Document:

EX-10.4

 Exhibit 10.4 

Tennessee Valley Authority 
 Coal Acquisition & Supply 
 1101 Market Street, MR 2A 

Chattanooga, Tennessee 37402-2801 
 CONTRACT SUPPLEMENT 
  

									
	TO:	  	Armstrong Coal Company, Inc.	  		  	Supplement No.	  	2
		  	7701 Forsyth Boulevard—10th Floor	  		  	Date	  	October 9, 2009
		  	St. Louis, Missouri 63105	  		  	Group-Contract No.	  	635-40685
		  		  		  	Plant	  	Various
		  		  		  	Name of Mine	  	Various

 Attention: Mr. Martin Wilson 
 This confirms the October 1, 2009, agreement reached between both parties relative to freeze proofing deliveries under the subject contracts. 
 As agreed, the freeze proofing products that will be applied to TVA’s shipments will be FreeFlowFC-100 for body feed application and FreeFlowSR-300 for side car release application. Both products are
manufactured by AKJ Industries, and will be applied to coal loaded for TVA’s fossil plants as follows: 
  

	1.	Unless TVA notifies contractor otherwise, anytime the temperature at contractor’s loading facility is below 27 degrees Fahrenheit during the loading process,
contractor will apply approximately 2 pints of FreeFlowFC-100 to each ton of coal being loaded into railcars at Contractor’s facilities. This amount may be adjusted by mutual agreement of the parties to reduce the risk of frozen coal being
delivered to TVA’s plants. The exception to this rule applies in the event a cooling period is moving into the area in 48 hours, dropping the temperature for an extended period of time. 

 

	2.	The cost to TVA for applying FreeFlowFC-100 will be $2.00 per gallon or $.50 per 2 pint application. 

 

	3.	The cost to TVA for applying the side care release application, FreeFlowSr-300, upon TVA’s request, will be $2.80 per gallon or $.35 per 1 pint application.

  

	4.	Contractor will invoice separately for the cost of applying FreeFlowFC-100 and FreeFlowSR-300. Each invoice and all correspondence relating to the application of the
freeze conditioning substance(s) should clearly reflect the Contract number, Traffic Control Number, and the cost of such treatment. Invoices for freeze conditioning should be sent to the attention of Connie Gazaway at Tennessee Valley Authority,
1101 Market Street, MR 2A, Chattanooga, Tennessee 37402-2801. 

 Please complete the acceptance below and return
the copy of this contract supplement to this office. You should retain the original for your file. 

 In the event Contractor fails to execute this Supplement in the acceptance space provided
below or fails to return such executed Supplement to TVA, shipment of coal to TVA following the date of Contractor’s receipt of this Supplement shall constitute an acceptance by Contractor of all the terms and conditions of this Supplement,
unless within five (5) business days of the date of receipt of this Supplement, Contractor notifies TVA, both orally and in writing that this Supplement is not accepted. 

 

							
	Accepted	 	Armstrong Coal Co.	 		 	TENNESSEE VALLEY AUTHORITY
		 	Company	 		 	
				
	By	 	/s/ Martin D. Wilson	 		 	/s/ Connie S. Gazaway
		 	Signature	 		 	Connie S. Gazaway
		 		 		 	Fuel Transportation Specialist
			
	President	 		 	/s/
	Title	 		 		 	Contract Support Specialist
			
	11/5/09	 		 	/s/
	Date	 		 		 	Manager of Coal SupplyEX-10.5

 Exhibit 10.5 

TENNESSEE VALLEY AUTHORITY 
 COAL SUPPLY & ORIGINATION 
 1101 Market Street, MR 2A-C 

Chattanooga, Tennessee 37402-2801 
 CONTRACT SUPPLEMENT 
  

									
	TO:	  	Armstrong Coal Company, Inc.	  		  	Supplement No.	  	3
		  	7701 Forsyth Boulevard—10th Floor	  		  	Date	  	October 15, 2010
		  	St. Louis, Missouri 63105	  		  	Group-Contract No.	  	635-40685
		  		  		  	Plant	  	Paradise
		  		  		  	Name of Mine	  	Parkway

 Attention: Mr. Martin Wilson 
 This confirms the following recent agreement between the parties, involving Tate Rich representing Armstrong Coal Company, Inc. (“Armstrong”), and Connie Gazaway representing TVA: 

1. TVA has claimed Force Majeure on 103,840 tons of coal under Group-Contract No. 635-40685 at Paradise Fossil Plant (“Plant”) in calendar
year 2010 due to events at the Plant. TVA and Armstrong have mutually agreed to ship these tons in the 4th quarter of calendar year 2010 at a price reduction of $5.00 per ton or $51.71 per ton. 

All other terms and conditions of the contract remain unchanged. 
 Please complete the acceptance below and return a signed copy of this contract supplement to this office. You should retain the other signed copy for your files. 

 

							
	Accepted	 	Armstrong Coal Co.	 		 	TENNESSEE VALLEY AUTHORITY
		 	Company	 		 	
				
	By	 	/s/ Martin D. Wilson	 		 	/s/ Connie S. Gazaway
		 	Signature	 		 	Connie S. Gazaway
		 		 		 	Senior Fuel Transportation Specialist
			
	President	 		 	/s/
	Title	 		 		 	Contract Support Specialist
			
	10/27/10	 		 	/s/
	Date	 		 		 	Manager of Coal Supply

 TVA SENSITIVE INFORMATIONEX-10.6

 Exhibit 10.6 

Tennessee Valley Authority 
 Coal Supply & Origination 
 1101 Market Street, MR 2A 

Chattanooga, Tennessee 37402-2801 
 CONTRACT SUPPLEMENT 
  

					
	TO:	  	Armstrong Coal Company, Inc.	  	 Supplement No.         4

		  	7701 Forsyth Boulevard—10th Floor	  	
Date                           
July 8, 2011

		  	St. Louis, Missouri 63105	  	 Group-Contract No.   635-40685

		  		  	 Plant
                          Paradise

 Attention: Mr. Martin Wilson 
 As a result of reopener negotiations, TVA and Armstrong Coal Company, Inc., (“Armstrong”) hereby agree to the following modifications to Group-Contract No. 635-40685 (the Contract).

  

	 	1.	Section 2.1.1 of the Contract is hereby amended with respect to the Base Tonnage quantities of coal to be sold and purchased during Contract Year #4
(2012) and Contract Year #5 (2013) by adding the following new paragraph as the last paragraph in Section 2.1.1: 

 “Notwithstanding the foregoing or any other provision of this Contract to the contrary, TVA may, in its sole discretion, (1) elect to reduce or increase the Contract Year #4 (2012) Base
Tonnage by up to ten percent (10%), and/or (2) elect to reduce or increase the Contract Year #5 (2013) Base Tonnage by up to ten percent (10%). If TVA elects to exercise this right regarding the Base Tonnage, it may specify Base Tonnage
that is no lower than 900,000 tons and no greater than 1,100,000 tons for Contract Year #4 (2012) and/or Contract Year #5 (2013). TVA must provide written notice (letter or e-mail) of its election to Contractor no later than June 1, 2012,
with respect to the Base Tonnage for Contract Year 2012 and no later than June 1, 2013, with respect to the Base Tonnage for Contract Year 2013. Following timely receipt of notice of TVA’s election, the remaining undelivered Base Tonnage
shall be delivered ratably during the remainder of the relevant Contract Year or as TVA and Contractor may otherwise agree in writing. Any reductions in the Base Tonnage made, at TVA’s election pursuant to this paragraph, shall not be made up
or rescheduled. 
  

	 	2.	Section 6.0 of the Contract is hereby amended with respect to the price specified for Contract Year #4 (2012) and Contract Year #5 (2013) by deleting the
prices specified for those Contract Years in Section 6.0 and replacing the deleted Contract Year #4 and Contract Year #5 prices with the following new prices: 

 

					
	 Contract Year #4
	  	2012	  	$54.25* f.o.b. PAF
	 Contract Year #5
	  	2013	  	$55.88* f.o.b. PAF

  
 TVA RESTRICTED INFORMATION

  
 Page 1 of 2

	*	Note: The stated Base Price for Contract Year #4 and Contract Year #5 on Page 1 is not subject to any further automatic price escalation. The immediately preceding
sentence is not meant to and does not prevent price adjustments that may be made pursuant to Contract Section 8.0, Adjustment for Quality, and/or Section 10.2. Contract Cost Reimbursements (Law Change Assessments Costs).

  

	 	3.	All other conditions of the Contract remain unchanged and in full force and effect. 

 

									
	Accepted	 	Armstrong Coal Co.	 		 	Tennessee Valley Authority
		 	(Company)	 		 		 	
					
	By	 	 /s/ Martin D. Wilson
	 		 	By	 	 /s/ Connie S. Gazaway

		 		 		 	Connie S. Gazaway
		 		 		 	Asset Management Specialist (Senior)
				
	Title	 	President	 		 	 /s/

		 		 		 	Manager, Coal Acquisition
					
	Date	 	7/13/11	 		 		 	

  
 TVA RESTRICTED INFORMATION

  
 Page 2 of 2EX-10.7

 Exhibit 10.7 

Tennessee Valley Authority 
 Coal Supply & Origination 
 1101 Market Street, MR 2A 

Chattanooga, Tennessee 37402-2801 
 CONTRACT SUPPLEMENT 
  

					
	TO:   Armstrong Coal Company, Inc.	  	Supplement No.	  	5
	        7701 Forsyth Boulevard—10th Floor	  	Date	  	December 28, 2011
	        St. Louis, Missouri 63105	  	Group-Contract No.	  	635-40685
		  	Plant	  	Various

 Attention: Mr. Martin Wilson 
 This confirms the discussion between Bill McNally, TVA, and Adam Anderson, Armstrong Coal Company, Inc., “(Armstrong) to amend Contract 635-40685 (the “Contract”) as set forth below.

 1. The effective date of this Supplement is December 28, 2011 (the “Effective Date”). 

2. As of the Effective Date, TVA is exercising its right under the Contract’s Subsection 2.1.1. as revised by Supplement No. 4 to decrease the
Contract Year #4 (2012) Base Tonnage by ten percent (10%). For the sake of clarity, TVA’s Base Tonnage for Contract Year #4 (2012) will be reduced by 100,000 tons. 

 

									
	 Year
	  	Existing Commitment	 	  	New Commitment Under this Supplement	 
	 2012
	  	 	1,000,000 tons	  	  	 	900,000 tons	  

 All other terms and conditions of the contract remain unchanged. 

 

			
	Tennessee Valley Authority
		
	By	 	/s/ Connie S. Gazaway
		 	Connie S. Gazaway
		 	Asset Management Specialist
		
		 	/s/ Ray W. Popoynak
		 	Ray W. Popoynak
		 	Manager, Coal Acquisition

 TVA RESTRICATED INFORMATIONEX-10.8

 Exhibit 10.8 
 CONTRACT 
 FOR 

PURCHASE AND SALE 
 OF ILLINOIS BASIN COAL 
 ARMSTRONG COAL COMPANY, INC. 

 TABLE OF CONTENTS 
 Note: Page numbers will be adjusted to match final contract configuration 
  

							
	SECTION DESCRIPTION	  	PAGE #	 
			
	 1.
	 	 Contract Term
	  	 	2	  
	 2.
	 	 Quantity
	  	 	2	  
	 3.
	 	 Scheduling
	  	 	4	  
	 4.
	 	 Variations, Delays, and Interruptions in Deliveries
	  	 	4	  
	 5.
	 	 Source
	  	 	7	  
	 6.
	 	 Price
	  	 	8	  
	 7.
	 	 Sampling and Analysis
	  	 	8	  
	 8.
	 	 Adjustment for Quality
	  	 	13	  
	 9.
	 	 Quality and Specifications
	  	 	14	  
	 10.
	 	 Contract Price Adjustments
	  	 	16	  
	 11.
	 	 Remedies
	  	 	17	  
	 12.
	 	 Notices
	  	 	19	  
	 13.
	 	 Shipping Notices
	  	 	19	  
	 14.
	 	 Transportation
	  	 	20	  
	 15.
	 	 Payments, Invoices
	  	 	21	  
	 16.
	 	 Weights
	  	 	22	  
	 17.
	 	 Contract Management Specialist/Contracting Officer
	  	 	23	  
	 18.
	 	 Disputes
	  	 	23	  
	 19.
	 	 Clean Air Act and Other Environmental Requirements
	  	 	23	  
	 20.
	 	 [This section intentionally left blank.]
	  	 	23	  
	 21.
	 	 Credit Evaluation and Performance Assurance
	  	 	23	  
	 22.
	 	 Verification of Data, Inspection or Records and Mine Sources
	  	 	25	  
	 23.
	 	 Coal Mining and Reclamation and Conservation Requirements
	  	 	25	  
	 24.
	 	 Relationship of Parties – Producer’s Statement
	  	 	26	  
	 25.
	 	 Non-Assignability; Subcontracts; Designation and Termination of Agent
	  	 	27	  
	 26.
	 	 Waivers
	  	 	27	  
	 27.
	 	 Officials Not to Benefit
	  	 	27	  
	 28.
	 	 Small Business Policy
	  	 	27	  
	 29.
	 	 Liquidated Damages for Subcontracting Plans
	  	 	27	  
	 30.
	 	 Affirmative Action and Equal Opportunity
	  	 	28	  
	 31.
	 	 Safety and Health
	  	 	28	  
	 32.
	 	 Environmentally Acceptable Facilities; Clean Air and Water
	  	 	28	  
	 33.
	 	 Certification for Contracts, Grants, Loans, and Cooperative Agreements
	  	 	29	  
	 34.
	 	 Contract Components
	  	 	29	  
	 35.
	 	 Confidentiality
	  	 	29	  
		
	 EXHIBIT I: Example of Price Adjustment Calculations for Quality Variations
	  	 	31	  
	 APPENDIX A: Source Area and Authorized Sources
	  	 	32	  

  
 ii 

 Contract
                     

CONTRACT FOR PURCHASE AND SALE OF COAL 
 THIS AGREEMENT (the “Contract”), is made and entered into this 30th day of August, 2012, by and between TENNESSEE VALLEY AUTHORITY, a corporation organized and existing under an
Act of Congress (hereinafter called “TVA”), and Armstrong Coal Company, Inc., a Delaware corporation with its principal place of business located at 7733 Forsyth Boulevard, Suite 1625, St. Louis, Missouri 63105 (hereinafter called
“Contractor”). TVA and Contractor may be referred to individually in this Contract as a “Party” or collectively as the “Parties.” 
 W I T N E S S E T H: 

In consideration of the mutual covenants hereinafter stated, the Parties hereto agree as follows: 

DEFINITIONS 

“Contract Year” shall mean the twelve-month period commencing January 1, 2013, and ending December 31, 2013, and
thereafter, each calendar year commencing January 1st
and ending December 31st for the Contract Term set
forth below. 
 “Delivery Commencement Date” shall be that date set forth in Section 1 hereof for commencement of deliveries.
Such date may be changed only by a written supplement to this Contract, signed by both Parties, that expressly refers to the term “Delivery Commencement Date.” The actual date of commencement of deliveries shall not affect the Delivery
Commencement Date. 
 “Contract Management Specialist” shall be that TVA representative designated to administer the Contract on
behalf of TVA. 
 “Delivery Point” shall have the following meaning: The coal shall be: (i) either F.O.B. loaded in TVA-provided
barges at the Contractor’s dock facility located on the Green River at milepost 76.6, (ii) F.O.B. loaded in TVA-provided railcars at the Mine’s Midway load-out facility, and/or (iii) F.O.B. Paradise via Truck. TVA shall have the
right to use these delivery options to ship contracted tonnage to any of its facilities and may use contracted tonnage to facilitate test burn needs. 
 “Destination” shall have the following meaning: For (i) coal purchased F.O.B. origin and transported by TVA or TVA’s carrier to a transloading or blending facility or facilities and
(ii) coal purchased F.O.B. destination at such facility or facilities, each such facility shall be a “Destination.” For all other coal, each TVA fossil-fired power plant receiving coal purchased under this Contract shall be a
“Destination.” The initial Destination or Destinations is as follows: Widows Creek, Paradise, Kingston, Cumberland; and TVA may elect under Subsection 14.7 of this Contract to change or add Destinations from time to time. TVA reserves the
right to ship to any plant, third party, or other location any coal purchased under this Contract F.O.B. Contractor’s dock facility located on the Green River at milepost 76.6 or F.O.B. loaded in railcars at the Mine’s Midway load-out
facility. 
 “Receiving Plant” shall mean any TVA fossil-fired power plant that receives coal purchased under this Contract, whether
or not such coal is transported directly to such plant or is first transported to a transloading or blending facility. Where the coal received by a TVA fossil-fired power plant is intended to be used only in certain generating units of the plant,
because of the particular coal quality requirements of such units, such units shall be considered the “Receiving Plant.” 

  
 1 

	1.0	CONTRACT TERM 

 1.1
The “Base Term” of this Contract shall be for two (2) years commencing on January 1, 2013, and ending on December 31, 2014, and provides for the option for the Parties to exercise a total reopener effective January 1,
2015. Subject to the provisions in section 1.2 below, if agreed-to by both Parties, the term, price and other terms and conditions of this Contract may be reopened (the “Reopener Term”) for a potential additional total of four
(4) years commencing January 1, 2015 and ending on December 31, 2018, in two-year (2-year) increments, as provided in Section 1.2 below. If both Parties cannot agree to the Reopener Term, this Contract shall terminate on
December 31, 2014. The Base Term and the Reopener Term are subject to the terms and conditions provided below. 
 1.2 Either
Party may elect to commence Reopener Term negotiations by providing written notice to the other Party no later than April 1, 2014, for the purpose of extending the term, renegotiating the price and other terms and conditions of this Contract
for coal to be provided for a period of two (2) years commencing on January 1, 2015, and ending on December 31, 2016. Nothing herein is intended to require a Party who has participated in Reopener Term negotiations hereunder to
continue such negotiations, if, for any reason, such Party determines it is not in its best interests to do so. Neither Party shall be under any obligation to agree to or have any liability for failing to agree to a Reopener Term, if any. If the
Parties have not mutually agreed to a Reopener Term, this Contract will terminate on December 31, 2014, unless TVA and the Contractor have mutually agreed in writing no later than July 1, 2014, to continue the term of this Contract under
the existing terms and conditions until such expiration date as the Parties may mutually agree in writing. Neither Party shall be under any obligation to continue the term and existing terms and conditions of this Contract beyond December 31,
2014, or have any liability for refusing to agree to continue this Contract beyond December 31, 2014. 
 1.3 Only in the
event that the Parties have agreed to a Reopener Term as provided above and continued the term of this Contract beyond December 31, 2014, then either Party may elect to commence negotiations for a second Reopener Term (Second Reopener Term) by
providing written notice to the other Party no later than April 1, 2016, for the purpose of extending the term, negotiating price and other terms and conditions of this Contract for coal to be provided from January 1, 2017, for any period
of time up to December 31, 2018. Nothing herein is intended to require a Party who has participated in Second Reopener Term negotiations hereunder to continue such negotiations, if, for any reason, such Party determines it is not in its best
interests to do so. Neither Party shall be under any obligation to agree to or have any liability for failing to agree to a Second Reopener Term. If this Second Reopener Term negotiation provision has not been exercised, the Contract will terminate
on December 31, 2016, unless TVA and the Contractor have mutually agreed in writing no later than July 1, 2016, to continue this Contract through December 31, 2018 under the then existing terms and conditions, or until such earlier
expiration date as the Parties may mutually agree in writing. Neither Party shall be under any obligation to continue this Contract beyond December 31, 2016, or have any liability for refusing to agree to continue this Contract beyond
December 31, 2016. 
 1.4 Any agreement by the Parties to terms and conditions resulting from any Reopener Term or Second
Reopener Term negotiations shall be included in a fully executed supplement to this Contract. 
  

	2.0	QUANTITY 

 2.1.1
Subject to TVA’s right to reduce or increase quantities to be delivered, as hereinafter provided, the quantity of coal to be sold and purchased hereunder during each Contract Year shall be as follows: 

 

					
	 Contract Year
	  	Base Tonnage	 
	 2013
	  	 	1,000,000	  
	 2014
	  	 	1,000,000	  
	 2015 - 2018
	  	 	2,000,000	  

 The base Tonnage for Contract Years 2015-2018 shall apply only in the event that the Parties mutually
agree to continue this Contract in accordance with Section 1 above. 

  
 2 

 Note: Except as otherwise provided below, all annual tonnages will be delivered in ratable
monthly amounts or as directed by the Contract Management Specialist. 
 2.1.2 TVA may, in its sole
discretion, make an election to increase shipments of coal above the amounts of the Base Tonnage in Contract Year 2013 and Contract Year 2014 (the “Option Period”) by up to 500,000 tons per year (“the Option Tonnage”). If TVA
elects to exercise this right to the Option Tonnage, TVA must provide written notice (letter or e-mail) of its election to Contractor no later than October 30, 2012, for the Option Tonnage for Contract Year 2013 and no later than March 29,
2013, for the Option Tonnage for Contract Year 2014. If TVA elects to exercise the Option Tonnage in Contract Years 2013 and 2014, TVA shall have the additional option in the Contract Year in which TVA elected to exercise the Option Tonnage, to
increase shipments of coal above the Base Tonnage plus the Option Tonnage by an amount (the Additional Option Tonnage) up to the same amount of the Option Tonnage elected by TVA in that Contract Year, to be delivered equally on a quarterly basis.
For example, for Contract year 2013, if TVA elects Option tonnage of 225,000 tons, then TVA would have the option to elect Additional Option Tonnage of up to 225,000 tons, for a total tonnage of 1,450,000 tons in Contract year 2013 (1,000,000 tons
of Base Tonnage plus 225,000 tons of Option Tonnage plus 225,000 tons of Additional Option Tonnage. TVA shall provide Contractor ninety (90) days’ written notice prior to the beginning of each calendar quarter to schedule delivery of the
Additional Option Tonnage. For the first Quarter of this Contract, Contractor recognizes that TVA will not be able to provide Ninety (90) days notice to Contractor of its election to take the Additional Option Tonnage, if any, for Contract Year
2013 due to the date of execution of this Contract. Consequently TVA shall have the right to either notify Contractor of its election to take Additional Option Tonnage in Contract Year 2013 by October 30, 2012 or TVA may elect to include,
divided equally, the Additional Option Tonnage for Contract Year 2013 in the 2nd, 3rd, and
4th Quarters of 2013. 

2.1.3 The Base Tonnage for Contract Year 2013 and Contract Year 2014 shall be the first 1,000,000 tons delivered prior to the delivery of
any of the Option Tonnage and any of the Additional Option Tonnage in each Contract Year. The price that TVA pays for the Base Tonnage shall be the Base Price. The price that TVA pays for any Option Tonnage and for any Additional Option Tonnage,
shall be the Option Tonnage Base Price as provided in Section 6.0, Price, of this Contract. 
 2.1.4 TVA shall have
no obligation to purchase or schedule for delivery any quantity of the Option Tonnage in Contract Year 2013 or Contract Year 2014 until such time the Option tonnage is elected by TVA. Once the Option tonnage is elected in writing by the notification
dates reflected herein, these tons shall become part of the committed annual amount to be shipped. 
 2.1.5 TVA shall not be
required to accept any quantity of coal shipped during a week that is in excess of the Nominated Quantity, but if TVA accepts such excess quantity of coal, TVA shall require that such excess amount be deducted from the quantities to be shipped
during the following or subsequent months/week(s) in the Contract Year. 
 2.1.6 If at the expiration of the term of the Contract
less than the maximum tonnage has been scheduled for delivery, the Parties may by agreement extend the term of this Contract for a period sufficient to permit the delivery of tonnage in an amount up to the difference between the maximum tonnage and
the total scheduled. Neither Party shall be obligated to agree to such an extension. 
 2.1.7 This Contract is not and shall not
be construed as a contract for all of TVA’s coal requirements for any plant. TVA reserves the right to purchase coal from other suppliers in any amount during the term of this Contract. 

 

	2.2	 Notwithstanding the provisions of Subsection 2.1.1, above, if generation of electricity at a Receiving Plant is curtailed or interrupted for a period
of one week or more as a result of the operating requirements of TVA’s integrated electric generating system, including considerations of economic dispatch of TVA’s generating units, TVA may, from time to time, suspend or reduce
Contractor’s deliveries under this Contract by a percentage equal to the percentage reduction in electric output of the Receiving Plant resulting from such curtailment or interruption. If there is more than one Receiving Plant for this Contract
at the time of such curtailment or interruption, the suspension or reduction in deliveries shall apply only to such coal as, but for the curtailment or interruption, would have been received at the Receiving Plant

  
 3 

	 	
experiencing a curtailment or interruption. Such suspension or reduction in deliveries may continue as long as generation at such Receiving Plant is curtailed or interrupted; provided, however,
if TVA continues any such reduction or suspension for more than one hundred eighty (180) consecutive days, and the average weekly reduction or suspension during said one hundred eighty (180) day period was more than fifty percent
(50%) of the average weekly quantity scheduled under this Contract for delivery during such period, Contractor may notify TVA in writing, after such one hundred eighty (180) day period, of Contractor’s intent to terminate this
Contract ninety (90) days from the date of TVA’s receipt of such written notice, and this Contract shall, upon the passing of such ninety-day (90-day) period, terminate without further cost or obligation to either Party, unless TVA shall
have directed the cancellation of the suspension or reduction within forty-five (45) days of TVA’s receipt of Contractor’s notice of termination. 

 

	2.3	If the coal purchased hereunder is shipped to a blending / trans-loading facility for incorporation into a Blended Product(s) that is constituted from (i) coal
purchased hereunder and/or coal of like quality to that purchased hereunder (such coal together with coal purchased hereunder “Contract Quality Coal”) and (ii) other coal or coals of dissimilar quality (when blended with Contract
Quality Coal, the “Blended Product(s)”), which Blended Product(s) is transported to more than one TVA Receiving Plant (“Multiple Receiving Plants”), then the provisions of Subsection 2.2 shall be applied as follows: In the event
one or more of the Multiple Receiving Plants experiences a curtailment or interruption in generation as described above, TVA shall determine the total reduction in weekly usage of Contract Quality Coal associated with the curtailment(s) or
interruption(s) (“Contract Quality Coal Reduction”), and TVA may adjust downward weekly deliveries hereunder on the basis of the ratio of the Contract Quality Coal Reduction to the average total quantity of Contract Quality Coal TVA has
been receiving weekly for use in the Blended Product(s) based on receipts during the prior 30-day period. All provisions of Subsection 2.2 not inconsistent with this paragraph shall apply in the case of Blended Product(s) and Multiple Receiving
Plants. 

  

	2.4	Except where Contractor has terminated this Contract as provided in Subsection 2.2., suspensions or reductions under Subsection 2.2 or Subsection 2.3 shall not affect
the enforceability of this Contract and, on termination of the suspension or reduction, shipments shall resume pursuant to the terms and conditions of this Contract. Both TVA and Contractor shall be excused from their respective obligations
hereunder with respect to deliveries suspended or reduced pursuant to Subsection 2.2 or Subsection 2.3, and such deliveries shall not be rescheduled for delivery except by mutual consent of the Parties. 

 

	2.5.	Except in the case of any failure to deliver that is excused under Subsection 4.2., TVA may exercise the remedies afforded it under Section 11, Remedies, or
as otherwise provided by law, in the event Contractor fails to deliver coal as provided in this Section 2 or Section 3, Scheduling; provided, however, in lieu of other remedies, The Parties may mutually agree in writing, but shall
not be obligated to agree, that any such deficiency in deliveries of coal by Contractor may be rescheduled for delivery to TVA. 

  

	3.0	SCHEDULING 

  

	3.1	TVA shall provide Contractor with any changes to the quantities of coal to be delivered to TVA consistent with the requirements of Section 2, Quantity.
Contractor agrees to load TVA’s carrier’s trains or barges on arrival at Contractor’s loading point in accordance with the terms and conditions of TVA’s rail or barge transportation agreement(s). TVA maintains the right to
coordinate all deliveries under this Contract and others for the purposes of establishing a uniform delivery schedule for placement at Destinations and/or Receiving Plants. 

 

	3.2	Regardless of which Party contracts for transportation necessary to transport coal purchased and sold hereunder to the Destination, unless otherwise agreed, Contractor
shall be responsible for making timely arrangements for the scheduling of transportation equipment necessary to comply with the delivery schedule established by TVA. 

 

	4.0	VARIATIONS, DELAYS AND INTERRUPTIONS IN DELIVERIES 

  

	4.1	Time of shipment is of major importance to TVA. Contractor shall immediately notify TVA’s Contract Management Assistant of any expected deviation from the shipment
schedule established in accordance with Section 2, Quantity, and Section 3, Scheduling, of this Contract and of the cause and extent of the deviation, except in the case of variations in quantity from schedule of up to five
percent (5%). 

  
 4 

	4.2	Subject to the conditions hereinafter stated, neither Party shall be liable to the other for failure to deliver or accept delivery of coal as provided for in this
Contract if such failure was due to supervening causes not due to its own negligence, and which cannot reasonably be overcome by the exercise of due diligence. Such causes shall include by way of illustration, but not limitation: acts of God or of
the public enemy; insurrection; riots; strikes; nuclear disaster; partial or total outages of coal-fired units; floods; accidents; major breakdown of equipment or facilities (including, but not limited to, emergency outages of equipment or
facilities to make repairs to avoid breakdowns thereof or damage thereto), such equipment and facilities to include, but not limited to, power generation, unloading, stock-out and preparation plant equipment; fires; industry-wide carrier delays or
shortages of carriers’ equipment; embargoes; orders of acts of civil or military authority; or industry-wide shortages of materials and supplies. Nor shall TVA be obligated to accept delivery of coal hereunder to the extent that such causes
wholly or partially prevent the unloading, stockpiling, preparing, or burning of coal at a Destination or Receiving Plant that is receiving coal at the time the cause occurs, in which case TVA shall have no obligation to consign deliveries to
another destination or plant; provided, however, that if there is more than one Destination or Receiving Plant for this Contract at the time such cause occurs, TVA shall be excused from taking delivery of only such coal as would have been received
at the Destination or Receiving Plant experiencing such cause. Nor shall refusal of either Party to settle a strike on terms other than it considers satisfactory preclude the strike from being considered an excusable cause. The Party that is not
failing to deliver or accept delivery of coal as provided for in this section due to supervening causes not due to its own negligence, may terminate this Contract if the duration of an excusable failure to deliver or accept delivery of coal is for a
continuous period of one-hundred and eighty (180) days, or for a non-continuous period of one-hundred and eighty (180) days in any two-hundred ten (210) day period. The Parties may mutually agree in writing, but shall not be obligated
to agree, that the amount of tonnage of coal not delivered due to an excusable failure to deliver or accept delivery of coal in accordance with this section 4.2 may be rescheduled. 

 

	4.3	Contractor’s delays due to delays of its subcontractors will not be excusable under this Section 4 unless the delay of the subcontractor was also due to
causes beyond the control and without the negligence of the Contractor or its subcontractor, such as the causes listed above. The failure by Contractor or its subcontractor to obtain and maintain all federal, state, and other regulatory agency coal
mining permits, certificates, and licenses due to contractor’s or its subcontractor’s negligence, shall not excuse Contractor from any obligation under this Contract. Contractor represents and warrants that as of the date of execution of
this Contract, that Contractor owns and/or controls sufficient coal reserves to satisfy its obligations to provide Coal to TVA under this Contract, within areas covered by Contractor’s existing, valid mining permits. 

 

	4.4	The provisions of Subsection 4.2 shall not excuse a Party unless such Party failing to deliver or take coal shall give written notice to the other of such failure and
furnish full information as to the cause and probable extent thereof within ten (10) calendar days after the failure first occurs. In the case of the Contractor, said ten-day (10-day) period shall begin with the day following that on which
tonnage first becomes deficient under the established delivery schedule. In the case of TVA, this period shall begin on the day following that on which TVA first fails to take coal duly and properly delivered. Failure to give such notice and furnish
such information within the time specified shall be deemed a waiver of all rights under this Section 4 with respect to such coal or such tonnage scheduled for delivery prior to the date such notice and information are actually furnished.

  

	4.5	 In the event of partial failure to deliver, take, or unload coal which is excusable under this Section 4, the Parties shall prorate deliveries or
receipts of coal in substantially the same proportion based upon contractual commitments, (e.g. a fifty percent (50%) reduction in receiving or production capacity would result in a fifty percent (50%) reduction in scheduled deliveries for
each supplier or consumer). However, the Parties shall not be obligated to prorate a reduction in receipts or deliveries under coal supply contracts not affected by the failure because they have different modes of delivery or have substantially
different quality requirements, or because their scheduled delivery dates are not affected by the failure. During the periods TVA may experience such failures to take or unload coal; Contractor shall be permitted to sell such coal normally intended
for TVA. In the case of the period during which Contractor may experience such 

  
 5 

	 	
failures to deliver coal, TVA may purchase replacement coal. The disabling effects of such failures to deliver, take, or unload coal shall be corrected by the Party experiencing such failure as
soon as and to the extent reasonably practicable. 

  

	4.6	If the coal purchased hereunder is shipped to a blending / trans-loading facility for incorporation into a Blended Product(s) (as defined in Subsection 2.3 hereof),
which Blended Product(s) is transported to more than one TVA Receiving Plant (“Multiple Receiving Plants”), then the provisions of Subsection 4.2 shall be applied as follows: In the event one or more of the Multiple Receiving Plants
experiences a failure to take, unload or bum a Blended Product due to causes identified in Subsection 4.2, TVA shall determine the total Contract Quality Coal Reduction, (as defined in Subsection 2.3 hereof), and TVA may adjust downward weekly
deliveries hereunder on the basis of the ratio of the Contract Quality Coal Reduction to the average total quantity of Contract Quality Coal TVA has been receiving weekly for the Blended Product(s) based on receipts during the prior 30-day period.
All provisions of Subsection 4.2 not inconsistent with this Subsection 4.5 shall apply in the case of Blended Product(s) and Multiple Receiving Plants. This Subsection 4.5 shall not apply to excused failures to take coal due to events that affect
transportation, receipt, unloading, or handling of coal prior to blending. 

  

	4.7	TVA, by providing at least thirty (30) days’ prior written notice to Contractor, shall have the right to refuse any shipments otherwise scheduled for delivery
to a Destination or Receiving Plant during maintenance periods at such Destination or Receiving Plant. The Parties may mutually agree in writing, but shall not be obligated to agree, that the amount of tonnage of coal not delivered during
maintenance periods at such Destination or Receiving Plant may be rescheduled. 

 CERTIFICATE OF FORCE MAJEURE
INFORMATION 
 TVA CONTRACT NO. (INSERT CONTRACT NUMBER) (THE “CONTRACT”) 

1. [insert name], hereby certify that: 
 (a) I have prepared and submitted the attached Notice of Force Majeure in good faith and based upon facts and circumstances known personally to me; 

(b) to the best of my knowledge and belief, the information contained in the attached Notice is, as of the date of this Certificate,
accurate, complete, not misleading, and can be verified by supporting information currently in my possession or in the possession of other employees or officers of [insert company name] (“Contractor”) and nothing has been omitted
from the attached Notice the inclusion of which is necessary for the information contained in the attached Notice to be accurate, complete, and not misleading; 
 (c) to the best of my knowledge and belief, the failure to deliver coal as provided in the Contract is due to supervening causes beyond the control of Contractor, is not due to Contractor’s own
negligence, and cannot be reasonably overcome by the exercise of due diligence by Contractor, and 
 (d) I am duly authorized to
execute and submit this Certificate and attached Notice. 
 For the purposes of this certification, the term “Force
Majeure” refers to the conditions and causes set forth in Subsection 4.2 of the Contract, and the term “Notice” refers to the written notice described in Subsection 4.3 of the Contract. 

 

			
	  
	  	
	Name	  	
		
	  
	  	
	Title	  	

  
 6 

			
	  
	  	
	Company	  	
		
	  
	  	
	Date of Execution	  	

  

	5.0	SOURCE 

  

	5.1	The source of coal delivered under this Contract is of major importance to TVA. The provisions of this Contract pertaining to coal quality and quantity requirements,
price adjustments, federal and state legislation, and other matters are directly related to the source of coal. As used in this Section 5, “Source Area” shall mean the total coal reserve areas in each specified coal seam that are
within or contiguous to the permit areas identified in Appendix A; provided, that, within the Source Area, only the area(s) (for surfaced mined coal) or mine opening(s) (for underground mined coal) covered by the existing and proposed mine permit
areas identified in Appendix A are defined to be an “Authorized Source” of coal for delivery under this Contract. The mine area(s) and/or opening(s) located within the Source Area, but not covered by the mining permit(s) listed above, may
become an Authorized Source under the following procedures as mining progresses and the appropriate permit(s) and license(s) are obtained. Contractor shall notify TVA in writing at least sixty (60) days in advance of its intention to deliver
coal from any additional area(s) or mine opening(s) that is in the Source Area but which is not then authorized. TVA shall authorize such areas if the proposed source is owned or controlled by contractor or its affiliates and if, in TVA’s
reasonable judgment, the proposed source is capable of meeting the requirements of this Contract. TVA reserves the right to require Contractor to furnish any information and/or any guarantees TVA deems necessary bearing on the ability of any source
or proposed source to meet the requirements of this Contract and to make that information and / or any guarantees a part of this Contract. 

  

	5.2	Contractor shall immediately notify TVA in writing of any events affecting the size or location of the Authorized Source(s). All Authorized Sources under this Contract
shall be in compliance with the Federal Mine Safety and Health Act of 1977, as amended, all state and federal reclamation laws, including the Surface Mining Control and Reclamation Act of 1977, as amended, and regulations issued under such laws. If
Contractor fails to comply with this requirement, whether or not coal from such Authorized Source is then being delivered hereunder, TVA may exercise its rights under Section 11, Remedies. 

 

	5.3	Contractor expressly assumes the risk that the “Source Area” and Authorized Source(s) as scheduled by Contractor (subject to approval by TVA as set forth
herein) will permit the production of coal in such quantities and of such quality as will meet the requirements of this Contract. Coal shall not be delivered from any other source(s), or shipped from any other origin(s), or mined by any other
producer(s) unless authorized by TVA in writing prior to delivery. 

  

	5.4	Contractor agrees that until such time as “additional sources/permits/seams” of coal are approved under the Contract, the only Authorized Sources of coal for
TVA (as shown in Appendix A to this Contract and in Supplements to this Contract that may modify Appendix A) shall be used for delivery under this Contract. Contractor will create segregated stockpiles at each source and will ensure that TVA, or a
third party lab, which is approved in writing by TVA (Third Party Lab) and at TVA’s expense, has the right to collect samples at the above referenced segregated stockpiles for additional analysis. TVA also shall have the right to collect and
analyze the referee split for any loadings. At any time, with or without notice, TVA retains the right to inspect and sample Contractor’s segregated TVA stockpiles designated for shipment to TVA plants. TVA reserves the right to refuse to
accept shipments of coal from Contractor that are not in accordance with the agreed Section 5 Source provisions herein or that do not otherwise conform to the coal quality criteria of this Contract. 

 

	5.5	Regardless of the cause of or reason for a request by Contractor to approve a new Authorized Source outside the Source Area, TVA shall be under no obligation to approve
the tendered source as an Authorized Source, and TVA may withhold its approval on any basis or bases that TVA may deem appropriate, including purely economic considerations. 

  
 7 

 Notwithstanding the above, it is understood by the Parties that Contractor is an ongoing
entity, and that its ability to ship the quantities set forth in Section 2.1.1 above might require additional mines and permits to be added to the “Source Area” and the approval of these additional mines as “Authorized
Sources” by TVA. 
 In the event TVA withholds approval of such additional mines or seams based on “purely economic
considerations,” the quantities set forth in Section 2.1.1 above shall be adjusted accordingly by the Parties. 
  

	6.0	PRICE 

 6.1 TVA
shall pay Contractor the Base Price set forth below during Contract Years 2013 and 2014 for deliveries of the Base Tonnage and TVA shall pay Contractor the Option Tonnage Base Price set forth below during Contract Years #1 and #2 for deliveries of
any Option Tonnage and any Additional Option Tonnage. The Base Price and Option Tonnage Base Price are for coal delivered (i) F.O.B. loaded in TVA-provided barges at the Contractor’s Dock Facility, (ii) in TVA-provided railcars at the
Mine’s Midway load-out facility, and/or (iii) F.O.B. Paradise via Truck. 
  

					
	 Contract Year #1
	  	2013	  	Base Price: $45.50 per ton
	 Contract Year #1
	  	2013	  	Option Tonnage Base Price: $43.12 per ton
			
	 Contract Year #2
	  	2014	  	Base Price: $49.03 per ton
	 Contract Year #2
	  	2014	  	Option Tonnage Base Price: $46.47 per ton

 Note: The Base Tonnage delivered in Contract Years 2013 and 2014 shall be subject to the Base Price
quality adjustments applicable under Section 8, Adjustment for Quality of this Contract. The Option Tonnage, if any, delivered in Contract Years 2014 and 2014, shall be subject to the Option Tonnage Base Price quality adjustments
applicable under Section 8, Adjustment for Quality of this Contract. 
  

	7.0	SAMPLING AND ANALYSIS 

 7.01 Upon the commencement of deliveries under this Contract, the following applies: (Check one box only) 
  

					
	 ̈	  	TVA Sampling/TVA Analysis	 	Section 7.1
			
	X	  	Contractor Sampling/Contractor Analysis	 	Section 7.2
			
	 ̈	  	Contractor Sampling/TVA Analysis	 	Section 7.3

  

	 	7.02	Regardless of which method of sampling and analysis is selected for initial deliveries, TVA, may elect from time to time, with 30 days’ advance written notice, to
switch to a different method of sampling and/or analysis, in which event the appropriate alternative clause of this Section 7 shall govern. 

  

	 	7.03	Contractor shall provide to TVA on a quarterly basis the following analysis and testing as specified by TVA. Sample composite size of not less than 10,000 tons (unless
otherwise approved by TVA): 

  

					
	Size Consist	 	Mineral Ash	 	Ash Fusions
	HGI	 	Trace Elements	 	

  
 8 

	7.1	TVA Sampling/TVA Analysis 

  

	7.1.1	The sampling location shall be the Receiving Plant unless TVA notifies Contractor in writing that samples will be taken at other locations, including blending
facilities. Contractor may be present at the taking of samples, but TVA shall have no obligation to notify Contractor to be present. TVA may engage the services of a third party to take its samples hereunder, rather than using its own employees.
Except as provided below, in order for TVA sampling and analysis to govern, the following criteria shall apply: 

  

	 	7.1.1.1	Sixty five percent (65%) of the shipments shall have been sampled and analyzed in accordance with the methods described in the latest published edition of the
Annual Book of ASTM Standards. Samples must have been collected utilizing mechanical systems meeting ASTM D 2234 Type I, Condition B, Collection of a Gross Sample of Coal, which have been shown to be free of statistically significant bias. Systems
will be subject to a critical inspection according to ASTM D4702 annually. Analysis procedures used should be as follows: 

  

									
	  	 	 Parameter
	 	  	 	 Method
	  	  
		 	Residual Moisture	 		 	ASTM D 5142	  	
		 	Air Dry Moisture	 		 	ASTM D 3302 Note	  	
		 	Ash	 		 	ASTM D 5142	  	
		 	Sulfur	 		 	ASTM D 4239	  	
		 	Btu	 		 	ASTM D 5865	  	
		 	  

Note: Or General Industry Standards
	 		  	

  

	 	7.1.1.2	The lot size for each sample shall be by barge load for barge coal, by trainload for rail coal, and by daily truck deliveries for truck coal. 

 

	 	7.1.1.3	The sampling system shall be located in an area such that the sample collected to represent the shipment is collected only from coal that is from said shipment.

  

	7.1.2	Analysis data (total moisture, ash, sulfur, and Btu) shall be promptly made available to Contractor through access to a computer system or, at TVA’s option, may be
provided by other means. Moisture, ash, and sulfur values shall be reported to the nearest hundredth (.01) of a percent. Heat content shall be reported to the nearest whole Btu/lb. S02 content shall be calculated and reported to the nearest
hundredth (.01) of a pound. 

  

	7.1.3	All samples collected by TVA, or others at its direction, shall be properly air dried and prepared according to ASTM D2013 & D3302 or General Industry
Standards to produce a 60-mesh sample for analysis. The 60-mesh sample shall be divided into at least two parts and put in suitable airtight containers, the first container in each case to be used by TVA, or its designated commercial laboratory, to
determine the quality of coal sold hereunder for all Contract purposes, except as specifically provided below. The second container in each case shall be held available to TVA for a period of sixty (60) days from actual sampling date of the
coal, properly sealed and labeled, to be analyzed if a dispute arises between TVA and Contractor. If Contractor wishes to dispute a sample or analysis, it shall notify TVA in writing within such sixty-day (60-day) period. If Contractor fails to
provide such notice of dispute within such sixty-day (60-day) period, Contractor shall be deemed to have waived any claim or defense based on errors or omissions in the sampling or analysis operations as to the affected samples.

  

	7.1.4	Upon receipt of a notice of a dispute over the results or method of such sampling or analysis, TVA shall review and inspect the sampling and analysis equipment and
procedures and the second sample part will be analyzed by a third-party commercial laboratory to check for reproducibility. The third-party laboratory will follow the same ASTM analysis procedures outlined in Subsection 7.1.1, and the
reproducibility limits in those same standards will be used to judge reproducibility. If the review of the sampling and/or analysis indicates the original sampling or analysis was improperly performed or the results of the second analysis are not
within ASTM reproducibility limits, the original analysis report shall be declared erroneous, and the results of the second analysis will be conclusive for both Parties in regard to the analysis of the sample in question. Otherwise, the original
analysis report shall remain in full force and effect. 

  

	7.1.5	 Contractor shall also sample and analyze, or obtain services of a third party to sample and analyze, all shipments of coal to TVA under this Contract.
These analyses shall specify, at a minimum, the total moisture content, the ash content (as-received), the heat content Btu/lb (as-received), the sulfur content (as- received) and S02 (as-received) and must be electronically transmitted to the
Contract Management Specialist and other Parties designated by the Contract Management Specialist in a format acceptable to TVA. These analyses are required in order to provide information on the contents of coal received by TVA

  
 9 

	 	
within 24 hours (including weekends and holidays) or prior to unloading, whichever is earliest. TVA reserves the right not to unload coal at the Destination until after the appropriate analysis
is received. Contractor shall be responsible for any demurrage charges incurred by TVA as the result of Contractor’s failure to transmit the analyses when and as required. TVA may reject coal based on these analyses; however, nothing in this
Subsection 7.1.5 shall affect in any way TVA’s rights to appropriate contractual actions and adjustments for quality based on samples collected and analyzed in accordance with this Section 7. 

 

	7.1.6	In the event TVA does not sample at least sixty-five percent (65%) of the tonnage received in a calendar quarter, the Contractor’s samples shall be used for
the quality adjustment(s) for such quarter under Section 8, Adjustments for Quality, provided all Contractor samples for such quarter meet all criteria below: 

 

	 	7.1.6.1	Ninety-five percent (95%) of shipments shall have been sampled and analyzed in accordance with the methods described in the latest published edition of the Annual
Book of ASTM Standards, volume 05.05. Samples must have been collected utilizing mechanical systems meeting ASTM D 2234 Type 1, Condition B, Collection of a Gross Sample of Coal, which have been shown to be free of bias within the past year. The
bias testing procedure and precision used must be approved by TVA. Systems will be subject to a critical inspection according to ASTM D4702 prior to approval. Analysis procedures used should be as follows: 

 

									
	  	  	 Parameter
	  	  	  	 Method
	  	  
		  	Residual Moisture	  		  	ASTM D 5142	  	
		  	Air Dry Moisture	  		  	ASTM D 3302	  	
		  	Ash	  		  	ASTM D 5142	  	
		  	Sulfur	  		  	ASTM D 4239	  	
		  	Btu	  		  	ASTM D 5865	  	

  

	 	7.1.6.2	Sample analysis (total moisture, ash, sulfur, and Btu) and other data required by TVA to match data with shipment shall be provided to TVA in a format approved by TVA.

  

	 	7.1.6.3	The lot size for each sample shall be by barge load for barge coal, by trainload for rail coal, and by daily truck deliveries for truck coal. 

 

	 	7.1.6.4	Analysis for each sample shall have been received by TVA by electronic data interchange within seven (7) days of collection of said sample.

  

	 	7.1.6.5	The sampling system shall be located in an area acceptable to TVA such that the sample collected for shipment is collected only from coal that is loaded for said
shipment. 

  

	7.2	Contractor Sampling/Contractor Analysis 

 (Applicable if checked above or elected by TVA pursuant to this Section 7) 
  

	 	7.2.1	Contractor or third party collected samples shall be used for the quality adjustment(s) for each quarter under Section 8, Adjustments for Quality, provided all
samples for such quarter meet all criteria below: 

  

	 	7.2.1.1	One hundred per cent (100%) of shipments shall have been sampled and analyzed in accordance with the methods described in the latest published edition of the
Annual Book of ASTM Standards. Samples must have been collected utilizing mechanical systems meeting ASTM D 2234 Type I, Condition B, Collection of a Gross Sample of Coal, which have been shown to be free of statistically significant bias within the
past year. The bias testing procedure and precision used must be approved by TVA. Systems will be subject to a critical inspection according to ASTM D4702 prior to approval. 

 

	 	7.2.1.2	TVA shall have the right to approve any laboratory that performs analyses hereunder, and the laboratory will be subject to inspection and/or audit prior to approval.
Analysis procedures used should be as follows unless otherwise approved in writing by TVA: 

  

									
	  	  	 Parameter
	  	  	  	 Method
	  	  
		  	Residual Moisture	  		  	ASTM D 5142	  	
		  	Air Dry Moisture	  		  	ASTM D 3302	  	
		  	Ash	  		  	ASTM D 5142	  	
		  	Sulfur	  		  	ASTM D 4239	  	
		  	Btu	  		  	ASTM D 5865	  	

  
 10 

	 	7.2.1.3	Sample analysis (total moisture, ash, sulfur, and Btu) and other data required by TVA to match data with shipment shall be provided to TVA in a format approved by TVA.

  

	 	7.2.1.4	The lot size for each sample shall be by barge load for barge coal, by trainload for rail coal, and by daily truck deliveries for truck coal. 

 

	 	7.2.1.5	Analysis for each sample shall have been received by TVA by electronic data interchange within seven (7) days of collection of said sample.

  

	 	7.2.1.6	The sampling system shall be located in an area acceptable to TVA such that the sample collected for shipment is collected only from coal that is loaded for said
shipment. 

  

	 	7.2.2	If TVA samples any of the tonnage received in a calendar quarter, and if Contractor’s samples for that same tonnage during the quarter do not meet all of the above
criteria, TVA’s samples shall be used for said quarterly adjustment(s) for the tons represented by such samples. TVA may engage the services of a third party to collect its samples hereunder, rather than using its own employees.
Contractor’s samples shall be used for the remaining tons for said quarterly adjustment(s), provided such samples meet all of the above criteria. In the event there are some tons not sampled by TVA and not sampled by Contractor in accordance
with the above criteria, the quality adjustment for those tons will be based on a prorated calculation of the analyses of the TVA-sampled tons and Contractor-sampled tons. 

 

	 	7.2.3	In the event Contractor’s mechanical sampling system is not operating due to mechanical, electrical, or operational failure, Contractor shall immediately notify
TVA and accept TVA’s (or TVA’s agent’s) samples at the Destination or Receiving Plant. 

  

	 	7.2.4	Contractor agrees to ensure that all sampling equipment is properly maintained and adjusted so that each sample taken is proportionate and representative of the coal
delivered. TVA or its designated representative may observe any sampling or sample preparation performed by Contractor. Contractor shall furnish the results of bias tests on the sampling system, and the results must be acceptable to TVA. The sample
system shall be bias tested (batch interval of all system components), and shown to be free of statistically significant bias, at least every twelve (12) months. 

 

	 	7.2.5	 Contractor shall prepare the samples obtained as directed by TVA and shall divide such samples into at least three parts and place in suitable airtight
containers. Contractor will analyze the first part and electronically transmit the results to the Contract Management Specialist, in the form of an analysis report issued and certified by the laboratory approved by TVA, and to all other parties
designated by the Contract Management Specialist (TVA location or otherwise) within 24 hours (including weekends and holidays) or prior to unloading at Destination, whichever is earliest. Except as provided below, Contractor’s analysis results
obtained on this first part will be utilized by TVA to determine whether or not the coal covered by the sample will be unloaded at the Destination. TVA reserves the right not to unload coal until after the appropriate analysis is received.
Contractor shall be responsible for any demurrage charges incurred by TVA as a result of Contractor’s failure to transmit the analyses when and as required. TVA may reject coal based on these analyses. Within twenty-four (24) hours of coal
loading, Contractor shall have the second part identified by such sample number analyzed by either Contractor’s approved laboratory or an approved third-party laboratory. The analysis results obtained from the second part shall supersede the
first part sample results and will be utilized for all Contract purposes, including determining the price adjustment required to compensate for the difference between the quality of the coal actually shipped and the Contract Typical Analysis. The
third part (“referee sample”) will be retained by Contractor, for a minimum of sixty (60) days, to be analyzed by an independent 

  
 11 

	 	
laboratory (to be agreed upon by TVA and Contractor) in the event of a disagreement between the Parties regarding the results obtained on either of the other two parts. The results of the referee
analysis will be conclusive for both Parties in regard to the analysis of the sample in question. The cost of any such referee analysis shall be borne by the Party that requested it. 

7.3 Contractor Sampling/TVA Analysis 
 (Applicable if checked above or elected by TVA pursuant to this Section 7) 
  

	 	7.3.1	Contractor or third party collected samples shall be used for the quality adjustment(s) for each quarter under Section 8, Adjustments for Quality, provided all
samples for such quarter meet all criteria below: 

  

	 	7.3.1.1	Ninety-five percent (95%) of shipments shall have been sampled and analyzed in accordance with the methods described in the latest published edition of the Annual
Book of ASTM Standards,. Samples must have been collected utilizing mechanical systems meeting ASTM D 2234 Type I, Condition B, Collection of a Gross Sample of Coal, which have been shown to be free of statistically significant bias within the past
year. The bias testing procedure and precision used must be approved by TVA. Systems will be subject to a critical inspection according to ASTM D4702 prior to approval. Analysis procedures used should be as follows unless otherwise approved in
writing by TVA: 

  

									
	  	  	 Parameter
	  	  	  	 Method
	  	  
		  	Residual Moisture	  		  	ASTM D 5142	  	
		  	Air Dry Moisture	  		  	ASTM D 3302 te	  	
		  	Ash	  		  	ASTM D 5142	  	
		  	Sulfur	  		  	ASTM D 4239	  	
		  	Btu	  		  	ASTM D 5865	  	
		  	  

Note – or General Industry Standards.
	  	

  

	 	7.3.1.2	Sample analysis (total moisture, ash, sulfur, Btu and S02) and other data required by TVA to match data with shipment shall be provided to TVA in a format approved by
TVA. 

  

	 	7.3.1.3	The lot size for each sample shall be by barge load for barge coal, by trainload for rail coal, and by daily truck deliveries for truck coal. 

 

	 	7.3.1.4	Analysis for each sample shall have been received by TVA by electronic data interchange within three (3) days of collection of said sample.

  

	 	7.3.1.5	The sampling system shall be located in an area acceptable to TVA such that the sample collected for shipment is collected only from coal that is loaded for said
shipment. 

  

	 	7.3.2	If TVA samples any of the tonnage received in a calendar quarter, and if Contractor’s samples for that same tonnage during the quarter do not meet all of the above
criteria, TVA’s samples shall be used for said quarterly adjustment(s) for the tons represented by such samples. TVA may engage the services of a third party to collect its samples hereunder, rather than using its own employees.
Contractor’s samples shall be used for the remaining tons for said quarterly adjustment(s), provided such samples meet all of the above criteria. In the event there are some tons not sampled by TVA and not sampled by Contractor in accordance
with the above criteria, the quality adjustment for those tons will be based on a prorated calculation of the analyses of the TVA- sampled tons and Contractor-sampled tons. 

 

	 	7.3.3	In the event Contractor’s mechanical sampling system is not operating due to mechanical, electrical, or operational failure, Contractor shall immediately notify
TVA and accept TVA’s (or TVA’s agent’s) samples at the Destination or Receiving Plant. 

  

	 	7.3.4	 Contractor agrees to ensure that all sampling equipment is properly maintained and adjusted so that each sample taken is proportionate and
representative of the coal delivered. TVA or its designated representative may observe any sampling or sample preparation performed by 

  
 12 

	 	
Contractor. Contractor shall furnish the results of bias tests on the sampling system, and the results must be acceptable to TVA. The sample system shall be bias tested (batch interval of all
system components), and shown to be free of statistically significant bias, at least every twelve (12) months. 

  

	 	7.3.5	Contractor shall prepare the samples obtained as directed by TVA and shall divide such samples into at least three parts and place in suitable airtight containers.
Contractor will analyze the first part and electronically transmit the results to the Contract Management Specialist and all other parties designated by the Contract Management Specialist (TVA location or otherwise) within 24 hours (including
weekends and holidays) or prior to unloading at Destination, whichever is earliest. Except as provided below, Contractor’s analysis results obtained on this first part will be utilized by TVA to determine whether or not the coal covered by the
sample will be unloaded at the Destination. TVA reserves the right not to unload coal until after the appropriate analysis is received. Contractor shall be responsible for any demurrage charges incurred by TVA as a result of Contractor’s
failure to transmit the analyses when and as required. TVA may reject coal based on these analyses. Within twenty-four (24) hours of coal loading, Contractor shall send the second part identified by such sample number directly to TVA’s
Central laboratory by expedited delivery for analysis. The analysis results obtained from the second part shall supersede the first part sample results and will be utilized for all Contract purposes, including determining the price adjustment
required to compensate for the difference between the quality of the coal actually shipped and the Contract Typical Analysis. The third part (“referee sample”) will be retained by Contractor, for a minimum of sixty (60) days, to be
analyzed by an independent laboratory (to be agreed upon by TVA and Contractor) in the event of a disagreement between the Parties regarding the results obtained on either of the other two parts. The results of the referee analysis will be
conclusive for both Parties in regard to the analysis of the sample in question. The cost of any such referee analysis shall be borne by the Party that requested it. 

 

	8.0	ADJUSTMENT FOR QUALITY 

  

	8.1	The price that TVA pays to Contractor (the Base Price for Base Tonnage and the Optional Tonnage Base Price for Optional Tonnage and for Additional Option Tonnage) for
coal delivered and accepted under this Contract shall be subject to adjustments for quality as provided in this Section. As used in this Section 8, a “Quarterly Average Value” shall mean the weighted average value of the appropriate
quality component determined from all samples of coal collected and analyzed in accordance with Section 7 during a calendar quarter, based on the tonnage represented by the samples collected and corresponding analysis. 

 

	8.2	BTU Adjustment - For the coal accepted in each calendar quarter, an adjustment, calculated to the nearest cent per ton and using the then current Base Price or
Optional Tonnage Base Price applicable to such deliveries, shall be applied to the Contract price to account for variations in the Quarterly Average Value for as-received Btu/lb. compared to the Typical Analysis for as received Btu in
Section 9. This adjustment shall in no way be affected by Contract price adjustments under Section 10.2 “Law Changes”. (See EXHIBIT I for example of calculations.) 

 

	8.3	Ash Adjustment - For the coal accepted in each calendar quarter, an adjustment, calculated to the nearest tenth of a cent per ton at a rate of either
(1) $0.15 per ton (decrease) for each percentage point the Quarterly Average Value of ash (on an as received basis) exceeds the Typical Analysis for ash in Section 9, or (2) $0.15 per ton (increase) for each percentage point the
Quarterly Average Value for ash (on an as-received basis) is less than the Typical Analysis for ash, shall be applied to the Contract price. The calculation shall be prorated to cover any fractional percentage. (See Exhibit I for example of
calculations.) 

  

	8.4	Moisture Adjustment - For the coal accepted in each calendar quarter, an adjustment, calculated to the nearest tenth of a cent per ton at a rate of either
(1) $ 0.06 per ton (decrease) for each percentage point the Quarterly Average Value of moisture exceeds the Typical Analysis for Moisture in Section 9, or (2) $ 0.06 per ton (increase) for each percentage point the Quarterly
Average Value for Moisture is less than the Typical Analysis for Moisture, shall be applied to the Contract price. The calculation shall be prorated to cover any fractional percentage. (See Exhibit I for example of calculations.)

  
 13 

	8.5	Sulfur Dioxide Adjustment - For coal accepted in each calendar quarter, an adjustment, calculated to the nearest tenth of a cent per ton at a rate of either
(1) $0.25 per ton (decrease) for each tenth (1/10) of a pound per million BTUs the Quarterly Average Value of sulfur dioxide exceeds the Typical Analysis for sulfur dioxide in Section 9, or (2) $0.25 per ton (increase) for each
tenth (1/10) of a pound per million BTUs the Quarterly Average Value for sulfur dioxide is less than the Typical Analysis of sulfur dioxide in Section 9, shall be applied to the Contract price. The calculation shall be prorated to cover
any fractional amount tenth (1/10) of a pound. This adjustment shall in no way be affected by Contract price adjustments under Section 10. Contract Price Adjustments hereof. (See Exhibit I for example of calculation).

  

	8.6	As soon as practicable after the end of each calendar quarter, TVA shall submit to Contractor a report showing the Quarterly Average Values and any per-ton adjustments
determined under this Section 8 of the Contract. The number of tons of coal received by TVA during the calendar quarter shall be multiplied by said adjustments, and any resulting amount shall be paid promptly (or credited to the extent of any
offsetting debit) to the Party to whom it is due. The assessment of adjustments in accordance with the foregoing does not in any way impair TVA’s rights under the Contract or at law with respect to any failure by Contractor to meet the Typical
Analysis that gives rise to such adjustments. 

  

	9.0	QUALITY AND SPECIFICATIONS 

  

	9.1	All coal delivered under this Contract shall conform to the following Typical Analysis on a quarterly average as determined by sampling and analyses performed in
accordance with Section 7, Sampling and Analysis: 

  

															
	 	  	TYPICAL ANALYSIS1	  	 REJECTION/SUSPENSION
 SPECIFICATIONS3
	 	 	 
	 Lbs. of S02 per million Btu2
	  	 	5.0	  	  	lbs.	  	Not more than	  	 	5.0	 (P) 	 	lbs.
		  	  
	  
	 	  		  		  	  
	  
	 	 	
		  				  		  		  	 	5.2	 (C) 	 	
		  				  		  		  	  
	  
	 	 	
		  				  		  		  	 	6.0	 (WC) 	 	
		  				  		  		  	  
	  
	 	 	
	 Total Moisture
	  	 	11.0	  	  	%	  	Not more than	  	 	12.0	  	 	%
		  	  
	  
	 	  		  		  	  
	  
	 	 	
	 Sulfur (a/r max)
	  	 	2.9	  	  	%	  	Not more than	  	 	2.9	 (P) 	 	%
		  	  
	  
	 	  		  		  	  
	  
	 	 	
		  				  		  		  	 	3.0	 (C) 	 	
		  				  		  		  	  
	  
	 	 	
		  				  		  		  	 	3.5	 (WC) 	 	
		  				  		  		  	  
	  
	 	 	
	 Ash (as received)
	  	 	10.0	  	  	%	  	Not more than	  	 	12.0	  	 	%
		  	  
	  
	 	  		  		  	  
	  
	 	 	
	 Btu/lb. (a/r)
	  	 	11,500	  	  		  	Not less than	  	 	11,000	  	 	
		  	  
	  
	 	  		  		  	  
	  
	 	 	
	 Ash fusion temperature
	  				  		  		  				 	
	 Reducing atmosphere
	  				  		  		  				 	
	 Initial
	  	 	1980	  	  	°F	  	Not less than	  				 	
		  	  
	  
	 	  		  		  				 	
	 Softening
	  	 	2075	  	  	°F	  	Not less than	  				 	°F
		  	  
	  
	 	  		  		  				 	
	 Hemispherical
	  	 	2135	  	  	°F	  	Not less than	  				 	°F
		  	  
	  
	 	  		  		  				 	
	 Fluid
	  				  	°F	  	Not less than	  				 	°F
	 Volatile Matter (dry basis)
	  				  	%	  	Not less than	  				 	%
	 Grindability (Hardgrove Index)
	  	 	54	  	  		  	Not less than	  	 	45	  	 	
		  	  
	  
	 	  		  		  	  
	  
	 	 	
	 Chlorine (dry basis)
	  	 	.02	  	  	%	  	Not more than	  				 	%
		  	  
	  
	 	  		  		  				 	

 NOTES: 
  

	1	The Typical Analysis shall be used for the quality adjustments under Section 8. 

	2	Sulfur Dioxide calculated at 97.5% 

	3	Failure to comply with any of these specifications shall be a basis for rejections and suspensions or termination pursuant to Subsections 9.3. and 9.4.

	4	Paradise (P), Cumberland (C), Widows Creek (WC) 

  

	9.2	 The coal as-received shall have a top size not greater than two (2) inches and not less than one and one-fourth (1-1/4) inches, with at least
forty-five percent (45%) of the product larger than one-fourth (1/4) inch, and with at least eighty-five percent (85%) of the product larger than 28 mesh. Such sizes shall be determined by using screens with square openings. Coal
shall not exhibit a temperature in excess of 120°F, and it shall be substantially free from mining impurities and scrap such as drill bits, pieces of scrap metal or plate, plastic, rubber, rope, cloth, wire, cable, bone, slate, earth, rock,
pyrite, wood, or water, that can be 

  
 14 

	 	
kept out or removed with the exercise of reasonable care during mining, preparation and loading. Belt magnets should be employed by Contractor for metal removal when conveyor belt load outs are
employed. Coal shall be loaded in a manner that will ensure reasonably uniform consistency as to size and quality and shall not contain slurry pond material (washer tailings), gob pile material (mine refuse), petroleum coke, oxidized coal, or blends
of such materials, or create excessive amounts of dust during the unloading and transferring to storage. 

  

	9.3	If any coal delivered fails to meet any of the Rejection/Suspension Specifications in Subsection 9.1 on the basis of laboratory analysis or the requirements of
Subsection 9.2 on the basis of visual inspection or laboratory analysis, TVA may reject the coal at the source, loading point, Destination, or Receiving Plant. TVA’s acceptance of any amount of coal which does not meet these requirements shall
not constitute a waiver of any right which TVA may have under this Contract or as provided by law on account of the delivery of such coal. In the event TVA rejects any coal in accordance with this section, TVA will immediately notify Contractor of
the rejection and of the cause of rejection. In the case of coal rejected after loading, unless the cause for rejection is corrected, Contractor shall promptly remove the coal from the carrier’s equipment, from the transloading or blending
facility, or from TVA premises, as the case may be, at Contractor’s expense. In addition to excess costs as provided in Section 11, Remedies, Contractor shall reimburse TVA for any additional transportation costs, demurrage, equipment
repair or replacement costs, or handling expenses incurred by TVA in connection with any such rejection. TVA shall not be under any obligation or liability to assist Contractor in any corrective actions required to remedy the cause for rejection.

  

	9.4	If any coal delivered fails to meet any of the Rejection/Suspension Specifications stated in Subsection 9.1 or the requirements of Subsection 9.2., TVA shall have the
right to refuse to accept further deliveries from any or all mine sources under the Contract until Contractor provides assurance satisfactory to TVA that Contractor will comply with the Rejection/Suspension Specifications and the Subsection 9.2
requirements. Such assurance must be given in writing within seven (7) days after the beginning of such suspension. If Contractor fails to provide such satisfactory assurance within the time specified or provides such assurance but does not
correct the deficiencies that resulted in the Contractor’s failure to comply with any of the Rejection/Suspension Specifications or the requirements of Subsection 9.2 within seven (7) days after giving such assurance, TVA may then
terminate Contractor’s right to make further deliveries under this Contract. However, if TVA has suspended Contractor’s right to make further deliveries under the above provision two (2) times during any twelve-month period, TVA shall
have the immediate right, at its option, upon the third such violation occurring within any twelve (12) month period following the second such violation, to terminate Contractor’s right to make further deliveries under this Contract.
Contractor shall be responsible for all costs or damages incurred by TVA resulting from Contractor’s failure to comply with the Contract requirements. Damages or excess re-procurement costs may be determined in accordance with Section 11,
Remedies. 

  

	9.5	If the normal operations in conformance with the design capabilities of a Receiving Plant cannot be accomplished with the coal delivered hereunder, although the coal
complies with the quality and size requirements of this Section 9, TVA may (i) if such Receiving Plant is the only fossil plant receiving coal hereunder, then terminate Contractor’s right to make further deliveries, and this Contract
shall be cancelled without further obligation or liability to either Party; or (ii) if there is more than one Receiving Plant receiving coal hereunder, then reduce the schedule of deliveries under the Contract by the amount that otherwise would
have been received at the affected Receiving Plant. In the event of such a termination or reduction in deliveries, the Contractor may be given a reasonable opportunity to remedy the cause for termination or reduction, which may include the offer of
replacement coal. However, TVA is not obligated to accept offers of replacement coal. 

 Notwithstanding the above,
this subsection 9.5 shall not be invoked or applied by TVA unless and until TVA has demonstrated that every effort has been made by its receiving plants to bum Seller’s coal and such efforts have proven unsuccessful. 

 

	9.6	 The Parties agree that the Rejection/Suspension Specification for moisture set forth in this Section 9 for Contract Years #1 and #2 is 12.0%,
however, the Parties shall cooperate in good faith for deliveries of coal that exceed a moisture content of 12.0% that occur on a periodic basis as follows: if (i) Contractor delivers four consecutive trains to TVA that exceed the 12% moisture
Rejection/Suspension Specification, the 

  
 15 

	 	
fourth train may be rejected; (ii) if Contractor delivers two consecutive trains to TVA that exceed 12.5% moisture, the second train may be rejected; and/or (iii) any shipments under
the Contract exceeding 12.6% moisture may be rejected by TVA. In the event that any one of the aforementioned items are triggered, and prior to the submission of any rejection notification by TVA to Contractor, the Parties shall discuss in good
faith an alternative resolution to avoid any possible rejection. 

  

	10.0	CONTRACT PRICE ADJUSTMENTS AND COST REIMBURSEMENTS 

  

	10.1	Contract Price Adjustments: N/A 

  

	10.2	Contract Cost Reimbursements, 

  

	10.2.1	Law Change Assessment Costs. In the event of the issuance, enactment, promulgation, revision, new interpretation, change in enforcement, or amendment, that is
documented in written, publicly available, official agency guidelines, rules or similar materials (by way of example and not limitation, such as MSHA Handbooks, MSHA Program Information Bulletins, or MSHA Procedure Instruction Letters) issued to
Federal or State enforcement personnel, on or after August 15, 2012, of a Federal or State statute, regulation, ordinance, rule or other mandate, or of a final judgment, order, or decree of a judicial or regulatory body or agency:

 (i) relating specifically to coal mine safety, rescue, or emergency response or 

(ii) which assesses on a per-ton basis a tax, fee or other charge on coal (for example, and by way of illustration only, the Federal
Black Lung Excise Tax and severance tax on coal delivered hereunder), 
 but excluding all sales taxes, income taxes, franchise
or privilege taxes, employment taxes, ad valorem taxes (on real and personal property), other similar taxes, and royalties (“Law Change”), Contractor shall be entitled to a reimbursement of the actual additional costs incurred as a result
of such Law Change. Contractor shall notify TVA of such Law Change and supply from its records information satisfactory to TVA showing the direct effect, if any, of the Law Change upon the cost per ton of furnishing coal under this Contract for
which it seeks reimbursement. 
 If Contractor seeks reimbursement under Subsection 10.2.1 (ii), the reimbursement shall, subject
to Subsection 10.2.2, be equal to the additional per-ton assessment referenced therein which results from a Law Change. If Contractor seeks reimbursement under subsection 10.2.1 (i), the per ton reimbursement shall, subject to Subsection 10.2.2, be
equal to the total cost calculated on a per ton basis attributable to such a Law Change, provided however, the cost attributed to such Law Change shall be uniformly allocated over all coal tonnage produced by Contractor from the source affected by
such Law Change in the Contract Year such Law Change took affect (a “Law Change Cost Reimbursement”). 
 If a Law
Change increases Contractor’s cost of providing coal to TVA, a Law Change Cost Reimbursement shall be paid by TVA to the extent, and only to the extent, of the increased cost that is attributable to such Law Change effective on the later of
(a) the date TVA receives Contractor’s notice of the Law Change or (b) the date Contractor’s cost of providing coal is increased by the Law Change. If a Law Change decreases Contractor’s cost of providing coal to TVA, a Law
Change Cost Reimbursement shall be paid to TVA to the extent, and only to the extent, of the decreased cost that is attributable to such Law Change effective on the date such Law Change could be utilized to reduce Contractor’s costs whether or
not Contractor actually reduces such costs on such date. 
 This Subsection 10.2.1 does not apply to any (i) promulgation,
issuance, implementation, revision, new interpretation, change in enforcement or amendment of rules and regulations except to the extent, and only to the extent, such promulgation, issuance, implementation, revision, or amendment results from a Law
Change, or (ii) implementation of statutes or rules or regulations that are enacted, issued or promulgated on or before August 15, 2012 except for Law Changes as described above. Any reimbursement under this Subsection 10.2.1 shall not
include any portion of Contractor’s general and administrative expenses, or other corporate and overhead expense, and shall be subject to Subsection 10.2.2. 

  
 16 

	10.2.2	If: (i) an individual or combination of Law Change Cost Reimbursement(s) requested by Contractor on or after August 15, 2012 exceeds one dollar and twenty
cents ($1.20) on a per ton basis; or (ii) an individual or combination of Law Change Cost Reimbursement(s) requested by Contractor in any single Contract Year exceeds one-dollar and twenty cents ($1.20) on a per ton basis, then TVA may, at its
sole discretion and without further obligation or liability to either Party hereunder or at law, terminate the Contract upon sixty (60) days written notice given after such a reimbursement is requested by Contractor. In no event shall
TVA’s liability for Law Change Cost Reimbursement(s) exceed one-dollar and twenty cents ($1.20) in the aggregate, on a per-ton basis, in any single Contact Year. However, in lieu of termination, Contractor may elect to absorb the cost in excess
of the aforementioned limits, in which case the Contract shall remain in full force and effect. Contractor’s election must be set forth in writing within thirty (30) days of TVA’s notice of termination. Such election by Contractor
shall be irrevocable and binding for the reimbursement sought to the extent it exceeds the aforementioned limits and shall be effective as of the effective date of the Law Change. TVA may invoke the provisions of this Subsection 10.2.2 each and
every time the cost of a Law Change exceeds the per-ton cost limits set forth above. 

  

	10.2.3	Contractor shall submit to TVA quarterly invoices for all reimbursements sought under Subsection 10.2.1(ii), and all payments, including tentative payments subject to
review, for reimbursement(s) sought under Subsection 10.2.1 (ii) shall be made by TVA to Contractor within thirty (30) days of receipt of an invoice from Contractor for the same. Contractor shall submit to TVA invoices for all
reimbursements sought under Subsection 10.2.1 (i) at the time such reimbursements are requested, and all payments, including tentative payments subject to review, for reimbursement(s) sought under Subsection 10.2.1(i) shall be made by TVA to
Contractor within six (6) months of receipt of an invoice from Contractor for the same. 

  

	10.3	The increase, decrease or reimbursement under each subsection of this Section 10 shall be calculated separately to the nearest one-tenth (1/10) cent per ton.
Any changes (including a recalculation of a previously granted tentative price adjustment or reimbursement) considered applicable by Contractor shall be reported to TVA by Contractor with appropriate data necessary to verify the change. Contractor
must furnish such supporting evidence as may be requested by TVA. A request for a price adjustment or reimbursement considered applicable by Contractor must be submitted to TVA with appropriate documentation within one hundred eighty (180) days
of the date Contractor incurs a resulting cost change. Failure to do so shall constitute a waiver of Contractor’s right to any upward adjustment or reimbursement. Any overpayment made under these provisions may be deducted from any amounts
otherwise due Contractor. 

  

	10.4	Contractor agrees that, in the event TVA reimburses Contractor under this Section 10 for a cost incurred by Contractor and it is later determined that Contractor
is entitled to recover such cost from a third party, at TVA’s request Contractor shall use its best efforts to recover such cost and upon such recovery shall reimburse TVA for amounts previously paid by TVA based on said cost. Reasonable costs
incurred by Contractor in pursuing such recovery at TVA’s request shall be reimbursed by TVA; provided that where Contractor and/or other purchasers from Contractor also receive a benefit from pursuing such recovery, the cost thereof shall be
equitably prorated. 

  

	11.0	REMEDIES 

  

	11.1	This Subsection 11.1 does not apply to a situation where another Contract provision provides a different procedure, such as Subsection 9.4. If TVA in good faith
believes that Contractor has failed to comply with any term or condition of this Contract, the Contract Management Specialist shall give Contractor oral notice, to be followed by written confirmation, of any such violation. 

 

	 	11.1.1	If Contractor fails to correct a curable Contract violation within seven (7) days of first notice, TVA shall have the right to suspend Contractor’s right to
make further deliveries until Contractor provides adequate assurance to TVA that Contractor will comply with all provisions of this Contract, such assurance to be given in writing within seven (7) days after such suspension. If Contractor fails
to provide such adequate assurance within the time specified or timely provides such satisfactory assurance but Contractor does not correct the curable Contract violation(s) within seven (7) days after giving such assurance, TVA shall have the
right, but not the obligation, to terminate Contractor’s right to make further deliveries under this Contract. 

  
 17 

	 	11.1.2	In the case of a Contract violation by Contractor or Contractor’s Subcontractor that (i) is not curable (including, but not limited to, violations of
Section 5, Source, of this Contract or Section 27 Officials Not to Benefit), or (ii) is a violation of any Federal or state law or regulation or county or municipal enactment, ordinance or code, including but not limited
to laws and regulations described in Subsection 14.6, upon providing notice as described above, TVA shall have the immediate right, but not the obligation, to terminate, or suspend for up to thirty (30) days, Contractor’s right to make
further deliveries under this Contract. If TVA suspends Contractor’s right to make further deliveries, then, upon expiration of such suspension, TVA shall either direct Contractor to continue performance of this Contract or terminate
Contractor’s right to make further deliveries. 

  

	11.2	Contractor shall be responsible for all costs or damages incurred by TVA resulting from Contractor’s failure to comply with the Contract requirements. TVA may, at
its option, purchase in the open market or by Contract or otherwise procure coal to replace all or any part of (i) that which was rejected by TVA or which the Contractor has failed to deliver, or (ii) that as to which its right to deliver
was terminated or suspended. Except as provided in Section 4, Variations. Delays, and Interruptions in Deliveries. Contractor shall be liable to TVA for the excess cost occasioned by such purchase(s) and any other loss or damage caused
by Contractor’s breach of the Contract, including, but without limitation to, liability incurred by TVA with respect to the transportation or other handling of the coal. In the alternative, TVA may, at its election, determine the loss or damage
sustained as a result of Contractor’s breach of contract by any other commercially reasonable methods or as provided by law. In addition to all other means of recovery, TVA may deduct any such excess costs and damages from any amount otherwise
due Contractor under this Contract or otherwise. 

  

	11.3	TVA may, at its election, determine its excess costs resulting from any deficiency, rejection, suspension, or termination in the following manner: (1) such part of
the highest-delivered-cost coal (of comparable quality under one or more contracts) which TVA purchases at the next awarding of term or spot contracts for delivery to any fossil plant in the TVA system as would be required to replace coal which was
scheduled for delivery under this Contract after the date the Contractor’s right to make deliveries under this Contract was terminated shall be deemed to have been purchased as Replacement Coal for Contractor’s account; and (2) for
unexcused deficiencies occurring before termination or Contract expiration, such part of the highest-delivered-cost coal (of comparable quality under one or more contracts) which TVA receives under term or spot contracts in the week following each
such deficiency, for delivery to any plant in the TVA system, as equals the quantity of Contractor’s deficiency shall be deemed to have been purchased as Replacement Coal for Contractor’s account. Contractor shall be liable to TVA for the
difference between the delivered cost of such Replacement Coal and the delivered cost of coal under this Contract (not including quality adjustments under this Contract). The delivered cost shall include transportation and handling costs, as well as
coal price, and shall take into account any differences between the quality of Replacement Coal and the quality specifications of this Contract. 

  

	11.4	If TVA suspends or terminates Contractor’s right to make further deliveries hereunder or under any other provision of this Contract and such suspension or
termination is finally determined in accordance with Section 18, Disputes, to have been improper, then Contractor’s sole remedy for such improper termination or suspension shall be to require TVA to reschedule all coal Contractor
was prevented from delivering due to such termination or suspension, such coal to be rescheduled for delivery on dates acceptable to both Parties, but in any event not later than Contract expiration. The price to be paid for such rescheduled coal
shall be the price in effect under the provisions of this Contract at the time of delivery. 

  

	11.5	In addition to the specific remedies provided for herein, in the event of a breach, TVA shall have all rights and remedies provided by law or equity.

  
 18 

	12.0	NOTICES 

 Unless
otherwise provided for in the Contract, any contractual notice required to be given to either Party shall be given by registered, certified, or first-class mail, electronic facsimile, or e-mail, to the intended Party at the following address or at
such changed address as may from time to time be designated in a notice similarly delivered or mailed. Except as expressly provided herein, any notice shall be deemed to have been given when sent. Communications by electronic facsimile or e-mail
shall be confirmed by depositing, within twenty-four (24) hours after sending the electronic facsimile or e-mail, a copy of the same in the post office for transmission by registered, certified, or first-class mail in an envelope properly
addressed as follows: 
 In the case of Contractor to: 
 Martin Wilson, President 
 Armstrong Coal Company, Inc.

 7733 Forsyth Boulevard – Suite 1625 

St. Louis, MO 63105 
 314-721-8211 (FAX) 
 mwilson@armstrongcoal. com

 With copy to: 
 Adam Anderson, Director, Sales/Marketing 
 Armstrong Coal
Company, Inc. 
 7733 Forsyth Boulevard – Suite 1625 

St. Louis, MO 63105 
 314-721-8211 (FAX) 
 aanderson@armstrongcoal.com

 Mason L. Miller 
 Miller + Wells, PLLC 
 300 Lexington, KY 40507

 (859) 957-1889 (FAX) 
 mmiller@millerwells.com 
 In the case of TVA to: 

Connie S. Gazaway 
 Contract Management Specialist 
 TVA 

1101 Market Street, MR 2A 
 Chattanooga, TN 37402-2801 
 423-751-3837 (FAX)

 csgazawa@tva.gov 
 Either Party may, by written notice to the other, change the representative or the address to which such notices and communications are to be sent. 

 

	13.0	SHIPPING NOTICES 

  

	13.1	For all coal shipped under this Contract, Contractor shall forward to the Contract Management Specialist and all other parties (TVA location or otherwise) as designated
by the Contract Management Specialist a shipping notification as to coal shipped. This shipping notice must include the Purchase Order number, line item number, release number, traffic control numbers, railcar/barge/truck numbers, origin, name of
mine, size of coal, shipping date, and such other relevant information as TVA may from time to time require. TVA shall have the right to require Contractor to transmit all of the above-referenced information via electronic data transfer direct to
TVA’s computer system. Contractor is responsible for ensuring that its computer system is compatible with TVA’s computer system. 

  
 19 

	13.2	Contractor must take whatever steps are necessary to ensure that shipping notices are received by the Contract Management Specialist and all other parties as designated
by the Contract Management Specialist prior to arrival of the coal at the Destination or within 24 hours of loading, including weekends and holidays, whichever is earliest. The Destination may not unload coal until a correct shipping notice is
received, and Contractor will be responsible to carrier or TVA for any demurrage charges resulting from delays due to late or improper notification. 

  

	13.3	In addition, on Monday of each week, Contractor must email a cumulative shipping notice to the Contract Management Specialist. This shipping notice will include such
items as Contract number, traffic control number, shipping date, conveyance ID, tonnage, quality and explanation for all variances from schedule. The format for this report will be provided by the Contract Management Specialist.

  

	14.0	TRANSPORTATION 

  

	14.1	TVA reserves the right to specify reasonable limitations on the type and size of transportation equipment, the method of transportation (including trainload lots and
barge load lots where lots are necessary to provide the lowest transportation rate possible), and the exact routing to be used, whether or not transportation to the Destination is the responsibility of TVA. TVA may reject any shipment made in
disregard of such specifications. If the Contract provides for a price or prices that include transportation in whole or in part to the Destination (f.o.b. destination contract), title to the coal and risk of loss and damage shall remain with
Contractor until delivery in acceptable condition by the carrier at Destination. 

  

	14.2	For all coal to be delivered hereunder, it shall be Contractor’s responsibility to load the coal and furnish loading devices which shall be suitable and fit for
the purpose contemplated in this Contract. Contractor shall be governed by carrier’s instructions regarding the height and distribution of the load, weight of cargo, and other instructions which carrier deems necessary for safe transportation.
Contractor shall allow carrier’s inspection of loaded equipment to assure compliance with carrier’s loading instructions. 

  

	14.3	For all coal shipped, it shall be Contractor’s responsibility to visually inspect the transportation equipment prior to each loading and ascertain that the
equipment is empty and suitable for loading. Any equipment found mechanically unsound for loading or contaminated with material shall not be loaded. Contractor shall not load any railcars with open doors. When loading barges, Contractor shall leave
the four comers of the barges open to allow easier removal of coal and accumulated water. Contractor shall be responsible for all costs incurred by TVA, including the cost of any coal lost in transit, resulting from Contractor’s failure to
comply with these requirements. 

  

	14.4	For all coal purchased for delivery by rail, whether f.o.b. origin or f.o.b. Destination, Contractor shall be responsible for loading each car to the appropriate
capacity as required by the rail carrier. In addition, each trainload shipment tendered under this Contract shall be loaded to the minimum trainload weight as required by the rail carrier. Contractor’s account will be charged with any charges
assessed to TVA because of Contractor’s failure to observe any minimum weight loading requirements. The gross weight of each car shall not exceed the maximum allowed by the carrier. If cars are found to be loaded in excess of such maximum, it
shall be Contractor’s responsibility to correct the load at Contractor’s expense, including but not limited to, Contractor’s payment to the carrier of switching charges, as well as any demurrage charges which may accrue while the car
or cars await correction in load. 

  

	14.5	Contractor shall be responsible for any demurrage that accrues at any loading point as a result of Contractor or its subcontractors not being prepared to load the coal
as scheduled. The carrier shall invoice Contractor and Contractor shall pay said carrier for all origin demurrage charges which accrue at the loading point(s). Contractor agrees to comply with the terms and conditions of TVA’s rail or barge
transportation agreement(s) with respect to loading. 

  

	14.6	 The explicit obligation of this Contract is that it will be performed in accordance with all applicable Federal, state, county and municipal laws,
regulations codes and ordinances, including, but not limited to, 

  
 20 

	 	
those applicable to transportation of coal. Transportation of coal by Contractor or by any third party transporting coal on Contractor’s behalf to rail or barge loading facilities, or any
other transportation by truck, shall comply with applicable highway laws and regulations governing the weight of vehicles and all other highway laws promoting public safety, health and welfare, including all laws governing the operation of vehicles
on any road or highway. To ensure compliance with this provision and to promote safety and compliance with laws governing vehicle operation, TVA may, as provided in Subsection 11.1.2, terminate or suspend further deliveries under this Contract on
account of violation of any motor vehicle laws or actions that, in TVA’s judgment, constitute unlawful or unsafe motor vehicle operations occurring in connection with any delivery of coal by truck. If any Contractor fails to comply with laws or
regulations governing the weight of vehicles, TVA shall have the same rights provided under Section 9, Quality and Specifications, for failure to meet the requirements thereof, including but not limited to the right to reject coal
delivered in overweight trucks. To ensure compliance with this provision and to help protect the roads and highways from overweight trucks, TVA may require that Contractor furnish a copy of the “certified” truck weight ticket. Regardless
of the actual weight of any truck coal received, the maximum gross weight that can be recorded for a single truck will be limited to the applicable maximum weight enforced by law. Any weight exceeding that maximum weight may be deducted from the
total weight of coal used for payment purposes. 

  

	14.7	TVA reserves the right to ship to any plant or other location any coal purchased F.O.B. any location. For coal purchased F.O.B. any plant or other location, TVA may
from time to time direct deliveries to any other plant or location, and if such deliveries cause an increase or decrease in the transportation cost borne by Contractor in performing this Contract, an adjustment shall be made in the Contract price to
reflect the changes in such cost. In addition, for coal purchased F.O.B. railcar and/or barge, TVA may, by giving prior written notice to Contractor as soon as possible but not later than thirty (30) days in advance, change the transportation
mode of delivery. 

  

	15.0	PAYMENTS, INVOICES 

  

	15.1	Payments under this Contract are subject to the provisions of the Prompt Payment Act (31 U.S.C. Sections 3901-3907). Payments as are provided for in the Contract or by
law will be made by Electronic Fund Transfer (EFT). EFTs will be made not more than fifteen (15) calendar days after the later of (1) receipt of a proper invoice(s) by TVA at: 

Accounts Payable Department 
 P.O. Box 15500 
 Knoxville, Tennessee 37901-5500 

Fax Number: (865) 632-6609 or (865) 632-4019 
 Email accountspayable@tva.gov 
 or 2) receipt and unloading of the coal at
the Destination. In preparing invoices, Contractor shall multiply the number of tons delivered by the Base Price applicable at the F.O.B. point of delivery plus or minus any adjustments that have been made effective under Contract provisions.
Payments shall be made in United States funds and timely sent to Contractor via EFT transfer to the following account: 
  

			
	Bank Name:	  	U.S. Bank, 10 N. Hanley Rd., St. Louis, MO 63105
	ABA Number:	  	081000210
	Bank Account Name:	  	152306681361
	Bank Account Number:	  	Armstrong Energy, Inc.

  

	15.2	For purposes of this provision only, “proper invoice” shall mean a numbered and dated invoice containing the complete name of Contractor, agent’s name
(if any), Purchase Order number, Release number, Destination, total amount due, correct weights (as defined below), traffic control number, shipping date, name of mine at which the coal was produced, together with any documentation required to be
submitted therewith by any other provision of the Contract. 

  

	15.3	For freeze conditioning invoices, or invoices for anything other than the tons delivered at the current price, the invoices should be mailed, faxed or emailed to the
Contract Management Specialist, using the notification information in Section 12. 

  
 21 

	16.0	WEIGHTS 

  

	16.1	Coal will be weighed or measured by TVA, Contractor, or independent laboratory technician (using scales or other appropriate method approved by TVA) at the location
where samples are collected for payment purposes. Except as specifically provided below, Contractor-provided weights will be used for Contract purposes where this Contract provides that Contractor samples are used for payment purposes, and
TVA’s weights will be used for Contract purposes when this Contract provides that TVA’s samples are used for payment purposes. When Contractor-provided weights are used, said weights will be reported to TVA by electronic facsimile or as
designated by the Contract Management Specialist for each shipment of coal hereunder. TVA shall have the right to have a representative present, at TVA’s sole risk and expense, at any and all times during TVA loadings to observe determination
of weights. Contractor shall notify TVA immediately upon the occurrence of inaccurate weighing or absence of actual weighing. Contractor shall confirm such notification in writing to TVA within seven (7) working days of the date of each such
occurrence. Such confirmation shall identify each affected coal shipment by Purchase Order number, line item number, shipping point, traffic control number, shipping date, and car/barge/truck number(s). Contractor’s account shall be adjusted
for any coal inaccurately weighed, or not weighed; such adjustment to be made at whatever times such occurrence(s) becomes known to TVA. 

  

	16.2	All scales and weighing devices used by Contractor to determine the governing weight of coal shall be certified by the appropriate regulatory authority or a railroad
and shall be material tested annually by an independent third party at the Contractor’s expense and the results of such tests provided to TVA within thirty (3) days of receipt of such test results of Contractor. Such scales and weighing
devices shall comply with the National Institute of Standards and Technology Handbook 44 and shall be installed, maintained, and operated according to manufacturers’ recommendations. 

 

	16.3	If Contractor-provided weights are to be used, and Contractor fails to provide proper weights, TVA weights will be the means by which the weight of coal sold,
delivered, and purchased hereunder shall be determined. Contractor shall reimburse TVA for any cost or expense charged to or incurred by TVA as a result of the absence of proper weights from Contractor, and TVA may elect to have TVA’s sampling
and analysis govern for quality adjustment purposes as to any coal not properly weighed by Contractor. While TVA may not undertake to weigh all coal received, it may at its option check weigh any coal received. In the event invoiced weights exceed
TVA weights by more than one and one-half percent (1.5%), a full material test will be run by both Parties with each Party responsible for its own cost. The weights that are determined most accurate shall govern. 

 

	16.4	Scale tests shall be performed more often than annually if reasonably requested by TVA. TVA shall be responsible for the cost of additional (more than annual) requested
tests unless the results thereof show that the scale failed to conform to certification standards, in which event the Contractor shall be responsible for such costs. 

 

	16.5	If Contractor’s or TVA’s weighing devices or methods are determined by said independent third party to be in error over 0.5%, an appropriate adjustment shall
be made to the affected weights and related invoices and payments reflecting the full extent of the error. Such adjustments shall be made retroactively to a date midway between the date on which the weighing devices were last tested and calibrated
and the date on which the inaccuracy in weighing methods or devices was first questioned and prospectively until the date on which the weighing methods and devices are corrected. 

 

	16.6	If scales at the applicable mine determine the weight for less than all of the railcars in a single trainload lot, then the average railcar weight for the last three
trainload lots to TVA, for trains that contained railcars all of the same capacity as the unweighed cars, shall be determined by dividing the trainload lots’ weight by the number of railcars in the trainload lots. The average railcar weight
shall be multiplied by the number of railcars in the unweighed or partially unweighed trainload lot to determine the trainload lot weight. 

  
 22 

	17.0	CONTRACT MANAGEMENT SPECIALIST/CONTRACTING OFFICER 

 The Senior Manager of Coal Supply and Origination has designated the Contract Management Specialist who administers this Contract for TVA to act on behalf of TVA for all purposes in the administration of
this Contract, such designation to continue until revoked or modified by the Senior Manager of Coal Supply and Origination. The Contract Management Specialist shall serve as TVA’s “Contracting Officer” with respect to matters arising
under terms of this Contract that provide for action by the Contracting Officer. 
  

	18.0	DISPUTES 

 The
Parties agree that any lawsuit between them that asserts a claim or claims arising out of or related to this Contract (whether sounding in Contract, tort, or otherwise) shall be filed and litigated to conclusion only in the United States District
Court for the Eastern District of Tennessee at Knoxville, and each Party hereby consents to the jurisdiction and venue of that court for all such lawsuits. The Parties further agree that in any such litigation (1) each will stipulate to have a
United States Magistrate Judge conduct any and all proceedings in the litigation in accordance with 28 U.S.C. § 636(c) and Fed. R. Civ. P. 73, and (2) each will waive any right it may have to a trial by jury. 

TVA is a Corporate Agency and instrumentality of the United States and this Contract shall be governed by and construed under Federal Law.
In the event Federal Law does not provide a rule of decision for any particular disagreement, the Law of the State of Tennessee shall apply; provided, however, in no event shall Tennessee’s choice of Law provisions apply. 

 

	19.0	CLEAN AIR ACT AND OTHER ENVIRONMENTAL REQUIREMENTS 

 In the event of enactment, implementation, amendment, or enforcement of the Clean Air Act, as amended, or any other applicable federal, state, or local air pollution control or environmental law, rule, or
requirement which causes the continued use of the coal purchased under this Contract to be inconsistent with (i) TVA’s air pollution control strategies, as they may be modified for meeting such air pollution control or environmental
requirements, or (ii) an administrative or judicial order, TVA may cancel this Contract with no further obligation or liability hereunder or at law by giving Contractor ninety (90) days’ advance notice of such cancellation. In the
case of inconsistency with TVA’s air pollution control strategies, the Parties will attempt to renegotiate the Contract during such notice period to provide for delivery of coal that will be of a quality consistent with TVA’s new air
pollution control strategies. In the event the Parties do not reach agreement on such a renegotiated Contract within the 90-day notice period, the cancellation notice given by TVA shall remain in effect and the Contract shall terminate at the end of
such period. In no event will TVA be obligated to divert deliveries from any affected Receiving Plant(s) to any alternate fossil plant or other destination. 
  

	20.0	[This section intentionally left blank.] 

  

	21.0	CREDIT EVALUATION AND PERFORMANCE ASSURANCE 

 21.1 Performance Assurance. Within five (5) business days of the execution of this contract, Contractor shall furnish Performance Assurance for the protection of TVA in the form of a parent
guaranty from Armstrong Energy, Inc. (“Guarantor”) and in a form reasonably acceptable to TVA and naming TVA as the beneficiary thereof, and within ten (10) days of the execution thereof, TVA will return any deposits,
with interest, held by TVA in connection with Contracts 612-40668 and 635-40685 between the Parties or their affiliates. TVA reserves the right to require additional Performance Assurance as it deems necessary over the term of the Contract.

  
 23 

 21.2 Material or Adverse Change in Financial Condition. Contractor and/or Guarantor shall inform TVA,
in writing, within ten (10) business days of any Material or Adverse Change in its financial condition. For the purposes of this Contract, a Material or Adverse Change is applicable to both the Contractor and the Guarantor, and shall include,
but is not limited to, any of the following: 
 If applicable to the Contractor: 

 

	 	1)	A voluntary bankruptcy filing, 

  

	 	2)	An involuntary bankruptcy filing that is not dismissed within sixty (60) days after filing, 

 

	 	3)	Insolvency, 

  

	 	4)	Appointment of receiver, trustee or examiner, 

  

	 	5)	A material default under other financing agreements with third-parties in excess of Ten Million Dollars ($10,000,000.00) that is not cured within ten (10) business
days from the date of the default, 

  

	 	6)	     

  

	 	7)	Entry of a judgment against Contractor’s in an amount that is greater than five percent (5%) of the Contractor’s net worth. 

If applicable to the Guarantor: 
  

	 	1)	A voluntary bankruptcy filing 

  

	 	2)	An involuntary bankruptcy filing that is not dismissed within sixty (60) days after filing, 

 

	 	3)	Insolvency, 

  

	 	4)	A report of a quarterly or annual loss or a decline in earnings of twenty percent (20%) or more compared to the prior period, 

 

	 	5)	A negative restatement of prior financial statements or a failure or refusal to provide quarterly or annual financial statements to TVA as required under Subsection
(21.5) below, 

  

	 	6)	A material default under other financing agreements with third-parties in excess of Ten Million Dollars ($10,000,000.00) that is not cured within ten (10) business
days from the date of the default, 

  

	 	7)	Appointment of a receiver, trustee or examiner, or 

  

	 	8)	Entry of a judgment against Guarantor in an amount that is greater than five percent (5%) of the Guarantor’s net worth. 

 

	 	9)	A delay in excess of thirty (30) calendar days to provide financial statements to TVA under Subsection (21.5) below where a delay is not deemed to be
excusable under Subsection (21.5; 1.d) below. 

 If there is a Material or Adverse Change in Contractor’s
and/or Guarantor’s financial condition, TVA may require Contractor to provide additional Performance Assurance, as outlined herein, within ten (10) business days of Contractor’s receipt of a written request from TVA for such
additional Performance Assurance, in an amount determined by TVA in a commercially reasonable manner and in a form and from a financial institution reasonably acceptable to TVA. If the Contractor fails to deliver such additional Performance
Assurance to TVA within ten (10) business days of receipt of TVA’s written request for such additional Performance Assurance, then the Contractor may be deemed by TVA to be in default under the terms of this contract. 

21.3 Types of Acceptable Performance Assurance. The types of acceptable Performance Assurance that TVA may require include but are not limited to:

  

	 	1)	Cash Deposit; 

  

	 	2)	An irrevocable standby letter of credit (including an increase or extension of an existing letter of credit) in a form and from a financial institution satisfactory to
TVA, or; 

  

	 	3)	Various combinations of the foregoing or other Credit or Performance Assurance reasonable acceptable to TVA. 

21.4 Remedies With Respect to Performance Assurance. In addition to any other remedies available under this Contract or at law, TVA, upon or any
time after the occurrence or deemed occurrence of a material default by the Contractor and/or Guarantor (and provided such default is continuing), may exercise any and all of its rights with respect to all Performance Assurance, including but not
limited to drawing on any outstanding letter of credit issued for TVA’s benefit and liquidating all Performance Assurance then held by or for the benefit of TVA free from any claim or right of any nature whatsoever of the Contractor. TVA shall
apply the proceeds from such Performance Assurance to reduce the Contractor’s obligation under the Contract, and the Contractor and/or Guarantor shall remain liable for any amount owing to TVA after the application of such proceeds. 

  
 24 

 21.5 Ongoing Credit Evaluation & Monitoring. TVA will monitor Guarantor’s
creditworthiness on an ongoing basis for changes in Guarantor’s financial condition. The Guarantor shall comply with the following provisions: 
  

	 	1)	Financial Statements: 

  

	 	a)	Within one hundred and twenty (120) calendar days following the end of each fiscal year, Guarantor shall deliver a copy of its annual report containing audited
consolidated financial statements for such fiscal year that include balance sheets, income statements, statements of cash flows and notes to the financial statements. 

 

	 	b)	Within sixty (60) calendar days following the end of each of the first three fiscal quarters of each fiscal year, Guarantor shall deliver a copy of its quarterly
report containing unaudited consolidated interim financial statements for such fiscal quarter. 

  

	 	c)	In all cases, Guarantor’s financial statements shall be prepared in accordance with generally accepted accounting principles used in the United States.

  

	 	d)	In the event any annual report or quarterly interim financial statements cannot be delivered on a timely basis due to a delay in preparation or certification, such
delay shall be excused to the extent, and only to the extent, Guarantor is diligently pursuing the preparation, certification, and delivery of the statements and has informed TVA in writing as to the cause or causes of such delay and the anticipated
duration of such delay. 

  

	 	2)	Within ten (10) business days of any change in majority ownership, Guarantor shall report such change and the details thereof to TVA. 

 

	 	3)	Within ten (10) business days of the occurrence thereof Guarantor shall disclose to TVA any material litigation, commitments or contingencies, etc.

  

	22.0	VERIFICATION OF DATA, INSPECTION OF RECORDS AND MINE SOURCES 

 TVA, its employees, agents, or representatives, shall have the right, after prior notice and at a reasonable time to inspect Contractor’s or, if applicable, its producer’s records and mines and
related facilities to verify the accuracy of the data supplied by Contractor to support its request for price adjustments or to establish Contractor’s actual cost change under section 10, Contract Price Adjustments, to review mine plans and
associated coal quality projections and maps, and for purposes of determining Contractor’s compliance with the provisions of this Contract. Information obtained by TVA, its employees, agents, or representatives, in examining Contractor’s
or its producer’s records or inspecting Contractor’s or its producer’s mines shall not be disclosed to third parties without the Contractor’s consent, unless disclosure is ordered by a court of competent jurisdiction, is made for
purposes of any litigation or proceeding (judicial, administrative, or investigatory) involving this Contract, or is otherwise required by law. 
  

	23.0	COAL MINING RECLAMATION AND CONSERVATION REQUIREMENTS 

 The following TVA reclamation and conservation requirements are applicable to all Contracts for the purchase of coal: 
  

	23.1	TVA Policy On Areas From Which Coal Will Be Procured: Coal Mining - Land and Water Resource Protection. TVA accepts no coal mined from locations in or near areas
officially designated by state or federal agencies, or identified by TVA, as wild or scenic river areas, wild, wilderness, natural, scenic, public recreation areas or under study pursuant to legislative authority for any such official designation,
except where special circumstances exist. No coal will be accepted from locations in or near areas designated under legislative authority as potential sites for the above uses unless, after coordination with the appropriate agencies, TVA determines
that the coal can be mined without substantially adversely affecting the area’s potential for such use. In such cases and also in cases involving offerings of coal from mines in or near other visually important areas such as major highways or
population centers, special provisions designed to protect aesthetic values may be incorporated in the purchase Contracts. No coal will be accepted from areas in which, in TVA’s judgment, mining would adversely affect a public water supply and
such adverse effect cannot be avoided by proper reclamation. 

  
 25 

	23.2	Contractor agrees that all sources of coal delivered shall be in full compliance with all state and federal reclamation laws, including the Surface Mining Control and
Reclamation Act of 1977 and all regulations issued thereunder. A violation of any such law or regulation shall constitute a breach of contract, entitling TVA to exercise its remedies as provided for in this Contract or by law. TVA will not accept
coal mined from any source, stockpile, or otherwise during any period when the source is subject to a cessation order issued by the Office of Surface Mining and Reclamation (OSM) or any state reclamation enforcement agency for violation of
reclamation requirements. 

  

	23.3	TVA also reserves the right to either terminate this Contract or suspend deliveries under the Contract from any source whatsoever when any Authorized Source is subject
to a cessation order. 

  

	23.4	Coal which is not delivered due to such cessation order or suspension shall not be considered excusable, and TVA may purchase replacement coal for the Contractor’s
account. If, upon appeal by the Contractor under OSM’s or the appropriate state’s regulations, a cessation order is held to have been improperly issued, the Contractor shall not be liable for the cost of replacement coal, and any coal not
delivered due to the order or suspension may, at Contractor’s option, be canceled or rescheduled upon delivery terms reasonably acceptable to TVA. This constitutes Contractor’s exclusive remedy against TVA in the event of a wrongful
issuance of a cessation order by OSM or a state agency. 

  

	23.5	TVA reserves the right to require and Contractor agrees to perform over and above the requirements specified by law any special or additional reclamation work which TVA
deems necessary to ensure that the mining operation complies with TVA’s overall policy for protection and enhancement of the environment. Any such special or additional reclamation work shall be subject to the approval of the U.S. Office of
Surface Mining, or a related agency having jurisdiction over the matter. TVA agrees to compensate Contractor for the performance of such work in an amount to be mutually agreed upon before the commencement of work. No work performed by Contractor
shall be deemed special or additional reclamation work for the purposes hereof unless it is so designated in writing by the Contract Management Specialist. 

 

	23.6	TVA, its agents, and assigns shall have the right to enter upon any of the land affected by Contractor’s mining operation, at any time and without the necessity of
giving notice, for any purpose related to enforcing these reclamation and conservation requirements or to observe mining or reclamation completed or in progress. 

 

	23.7	TVA will not accept coal from sources mined under the 16-2/3 percent exemption allowed under P.L. 95-87, unless it can be documented that the source will be mined and
reclaimed to the performance standards established under P.L. 95-87, and furthermore, that the operation has the concurrence of the coal mining and regulatory (primacy) authority established by this law in the state from which the coal is to
be mined. 

  

	24.0	RELATIONSHIP OF PARTIES – PRODUCER’S STATEMENT 

  

	24.1	Regardless of whether the Contractor is the producer of the coal to be furnished or is the sales agent of one or more producer, the Contractor binds and obligates
itself for the full and faithful performance of the Contract in its entirety. 

  

	24.2	If the Contractor is not the producer of the coal to be delivered hereunder, Contractor represents that it has contracted directly with the producer(s) who has (have)
executed the Coal Producer’s Statement(s) for the delivery of the coal to TVA. 

  
 26 

	25.0	NONASSIGNABILITY; SUBCONTRACTS; DESIGNATION AND TERMINATION OF AGENT 

 

	25.1.1	Neither this Contract nor any interest herein or any payments hereunder shall be assigned without the prior written consent of TVA, which consent TVA may withhold in
its sole discretion. In the event TVA shall give such consent, the same shall not be construed as a waiver of this provision with regard to any subsequent assignment. 

 

	25.1.2	Notwithstanding the foregoing, any Party may, without the need for consent from the other Party (and without relieving itself from liability hereunder), transfer, sell,
pledge, encumber or assign this Contract or the accounts, revenues or proceeds hereof or thereof in connection with any bank financing or security arrangements, provided, however, that no such assignment shall in any way relieve the assignor from
liability for full performance under this Contract. Any such assignee shall assume and agree to be bound by the terms and conditions of this Contract. Any consent to an assignment under this provision shall not be construed as a waiver of this
provision with regard to any subsequent assignment. 

  

	25.2	No designation of any agent by the Contractor to submit invoices, receive payments, or take any other action in connection with the performance or administration of
this Contract shall be effective or recognized by TVA until the Contractor has given written notice of such designation and TVA has given Contractor specific written notice of its approval thereof. 

 

	25.3	If Contractor notifies TVA in writing of the termination of any agent that Contractor may have previously designated to administer this Contract on its behalf, TVA may
thereafter rely on such notice of termination in all dealings with Contractor or a successor agent. 

  

	26.0	WAIVERS 

 No waiver
of any breach of this Contract shall be held to be a waiver of any other breach. Unless a remedy is expressly designated as exclusive, all remedies afforded under the Contract shall be in addition to every other remedy provided herein or by law.

  

	27.0	OFFICIALS NOT TO BENEFIT 

 No member of or delegate to Congress or Resident Commissioner, or any officers, employee, special Government employee, or agent of TVA shall be admitted to any share or part of this Contract or to any
benefit that may arise therefrom unless it be made with a corporation for its general benefit; nor shall the Contractor offer or give, directly or indirectly, to any officer, employee, special Government employee, or agent of TVA any gift, gratuity,
favor, entertainment, loan, or any other thing of monetary value, except as provided in 5 C.F.R. part 2635. Breach of this provision shall constitute a material breach of this Contract and TVA shall have the right to exercise all remedies provided
in this Contract or at law. 
  

	28.0	SMALL BUSINESS POLICY 

 The requirements of 15 U.S.C § 637(d) are incorporated by reference. 
  

	29.0	LIQUIDATED DAMAGES FOR SUBCONTRACTING PLANS 

  

	29.1	Failure to make a good-faith effort to comply with the subcontracting plan, as used in this clause, means a willful or intentional failure to perform in accordance with
the requirements of the subcontracting plan approved under 15 U.S.C. 637(d) or willful or intentional action to frustrate the plan. 

  

	29.2	Performance shall be measured by applying the percentage goals to the total actual subcontracting dollars or, if a commercial plan is involved, to the pro rata share of
actual subcontracting dollars attributable to Government contracts covered by the commercial plan. If, at Contract completion, or in the case of a commercial plan, at the close of the fiscal year for which the plan is applicable, the Contractor has
failed to meet its subcontracting goals and the Contracting Officer decides in accordance with Subsection 29.3 that the Contractor failed to make a good-faith effort to comply with its subcontracting plan, the Contractor shall pay TVA liquidated
damages in an amount equal to the actual dollar amount by which the Contractor failed to achieve each subcontract goal. 

  
 27 

	29.3	Before the Contracting Officer makes a final decision that the Contractor has failed to make such good-faith effort, the Contracting Officer shall give the Contractor
written notice specifying the failure and permitting the Contractor to demonstrate what good-faith efforts have been made. Failure to respond to the notice may be taken as an admission that no valid explanation exists. If, after consideration of all
the pertinent data, the Contracting Officer finds that the Contractor failed to make a good-faith effort to comply with the subcontracting plan, the Contracting Officer shall issue a final decision to that effect and require that the Contractor pay
the government liquidated damages as provided in paragraph b. of this section. 

  

	29.4	With respect to commercial plans, i.e., company-wide or division-wide subcontracting plans, the Contracting Officer of the agency that originally approved the plan will
exercise the functions of the Contracting Officer under this clause on behalf of all agencies that awarded contracts covered by that commercial plan. 

  

	29.5	The Contractor shall have the right of appeal, under the section in this Contract titled DISPUTES, from any final decision of the Contracting Officer.

  

	29.6	Liquidated damages shall be in addition to any other remedies that TVA may have. 

 

	30.0	AFFIRMATIVE ACTION AND EQUAL OPPORTUNITY 

 To the extent applicable, this Contract incorporates by reference the “Equal Opportunity” for Special Disabled Veterans and Veterans of the Vietnam Era clause, 41 C.F.R. § 60-250.5; the
“Equal Opportunity for Workers with Disabilities” clause, 41 C.F.R. § 60-741.5; and the “Equal Opportunity” clause, 41 C.F.R. § 60-1.4. 
  

	31.0	SAFETY AND HEALTH 

All sources supplying coal purchased under this Contract shall be in full compliance with the Federal Mine Safety and Health Act of 1977
and regulations issued thereunder. Failure to comply shall constitute a breach of contract, permitting TVA to exercise its remedies under this Contract or as provided by law. 

 

	32.0	ENVIRONMENTALLY ACCEPTABLE FACILITIES; CLEAN AIR AND WATER 

 Contractor hereby stipulates and agrees as follows: 
 (1) Contractor certifies that
performance of this Contract will not involve the use of any facility or facilities which have given rise to a conviction under Section 113(c) of the Clean Air Act (42 U.S.C. 7413(c)) or Section 309(c) of the Federal Water Pollution
Control Act (33 U.S. C. 1319(c). 
 (2) Contractor will comply with all the requirements of Section 114 of the Clean Air Act
and Section 308 of the Federal Water Pollution Control Act relating to inspection, monitoring, entry, reports, and information, as well as all other requirements specified in Section 114 and Section 308 of the Clean Air Act and the
Federal Water Pollution Control Act, respectively, and all regulations and guidelines issued thereunder in its performance of this Contract. 
 (3) Contractor will notify TVA of any conviction under Section 113(c) of the Clean Air Act or Section 309(c) of the Federal Water Pollution Control Act involving a facility to be utilized for
this Contract. 

  
 28 

	33.0	CERTIFICATION FOR CONTRACTS, GRANTS, LOANS AND COOPERATIVE AGREEMENTS 

Contractor’s representative, by signing this Contract, certifies, to the best of his or her knowledge and belief, that: 

(1) No Federal appropriated funds have been paid or will be paid by or on behalf of Contractor to any person for influencing or attempting
to influence an officer or employee of any agency, a member of Congress, an officer or employee of Congress, or an employee of a member of Congress in connection with the awarding of this Contract or the extension, continuation, renewal, amendment,
or modification of this Contract. 
 (2) If any funds other than Federal appropriated funds have been paid or will be paid to any
person for influencing or attempting to influence an officer or employee of any agency, a member of congress, an officer or employee of Congress, or an employee of a member of Congress in connection with this Agreement, Contractor shall complete and
submit Standard Form-LLL, “Disclosure of Lobbying Activities,” in accordance with its instructions. 
 This
certification is a material representation of fact upon which reliance was placed when this Contract was made or entered into. Submission of this certification is a prerequisite for making or entering into this Contract imposed by 31 U.S.C. 1352.
Any person who makes an expenditure prohibited under paragraph (1) of this clause or who fails to file or amend the disclosure form required to be filed or amended by paragraph (2) of this clause shall be subject to civil penalties as
provided for by 31 U.S.C. 1352. 
  

	34.0	CONTRACT COMPONENTS 

APPENDIX A (Source Area and Authorized Sources) and Exhibit I (Example Calculation of Price Adjustment for Quality Variations) are
attached hereto and made a part hereof. 
  

	35.0	CONFIDENTIALITY 

  

	35.1	Nondisclosure 

 Contractor
agrees not to divulge to third parties, without the prior written consent of TVA, any information that a prudent business person would consider sensitive or which is designated by TVA as proprietary or confidential, obtained from or through TVA or
developed or obtained by Contractor in connection with the performance of this Contract. Access to sensitive TVA information must be approved in advance by TVA’s Contracting Officer and CTS. If so requested by TVA, Contractor further agrees to
require its employees to execute a nondisclosure agreement prior to performing any services under this Contract. Notwithstanding the above, the preceding shall not apply if the information was public knowledge, already known by Contractor, was
obtained by Contractor from a third party who did not receive the information from TVA, or was independently developed by Contractor’s employees who did not have access to such information. This provision shall be made applicable to all
subcontractors under this Contract. 
  

	35.2	News Releases 

 Contractor
shall not make any announcement, take any photographs, post related information on any website, or release any information concerning this Contract, its business relationship with TVA, or any related project to any member of the public, press,
business entity, or any official body unless such release is required in compliance with any applicable Federal, State, or local laws, ordinances, statutes, rules, and regulations in effect at the time. The only exception to this Contract
requirement is, with prior approval for each request from TVA’s Contracting Officer, TVA may be used as a reference. Violations of this requirement may constitute a material breach of Contract. 

  
 29 

 (IN WITNESS WHEREOF, the Parties hereto have caused this agreement to be executed as of the aforesaid
date by their duly authorized representatives. 
  

							
	WITNESS:	 		 	CONTRACTOR	 	 Armstrong Coal Co.

							
				
	

	 		 	By:	 	

	  
	 		 		 	  

		 		 		 	Signature
				
		 		 	Title:	 	 President

			
	WITNESS:	 		 	TENNESSEE VALLEY AUTHORITY
				
	

	 		 	By:	 	

	  
	 		 		 	  

		 		 		 	Signature
				
		 		 	Title:	 	 VP Coal & Gas Services

  
 30 

 EXHIBIT I 
 EXAMPLE CALCULATION OF PRICE ADJUSTMENT 
 FOR QUALITY VARIATIONS 

Assume: 
  

									
	 	  	Typical Analysis	 	 	Qtrly. Avg. Value	 
			
	 Btu/lb. (as-received)
	  	 	12,000	  	 	 	12,125	  
	 Ash (as-received)
	  	 	7.00	% 	 	 	9.00	% 
	 Total Moisture
	  	 	12.00	% 	 	 	12.25	% 
	 S02 in lbs./mmBtu at 97.5%
	  	 	1.70	  	 	 	1.62	  

 Total Tons Received equals 100,000 
 Price equals $20.00 
 Ash Adjustment Increase/Decrease is $0.15 per percentage point 

Moisture adjustment increase/decrease is $0.06 per tenth of a percent 
 S02 adjustment increase/decrease is $0.25 per tenth of a lb. 
 Btu example for
Section 8.2. 
  

							
	Btu Adjustment	 	=	 	(Quarterly Average Value - Typical Analysis) X Price	  	
		 		 	                              
  Typical Analysis	  	

  

							
	Btu Adjustment	 	=	  	(12,125 - 12,000) X $20.00	  	
		 		  	                  12,000	  	
	Btu Adjustment	 	=	  	$0.21 per ton	  	

 Ash example for Section 8.3. 
 Ash Adjustment decrease = (Quarterly Average Value - Typical Analysis) X Adjustment 
 Ash
Adjustment decrease = (9.00 -7.00) X $0.15 
 Ash Adjustment decrease = $0.30 per ton 
 Moisture example for Section 8.4. 
 Moisture Adjustment decrease = (Quarterly Average
Value - Typical Analysis) X Adjustment 
 Moisture Adjustment decrease = ((12.25- 12.00)) X $0.06 

Moisture Adjustment decrease = $0.015 per ton. 

SO2 example for Section 8.5 (scrubbed plants). 
 S02 Adjustment increase = (Typical Analysis - Quarterly Average Value) X Adjustment 
 S02
Adjustment increase = ((1.70- 1.62) X 10) X $0.25 
 S02 Adjustment increase = $0.20 per ton. 

Sulfur Dioxide example for Section 8.5 non-scrubbed plants) 
 Cantor Fitzgerald Market Price Index 
  

					
	 Month A Index Value
	  	$	181.00	  
	 Month B Index Value
	  	$	163.00	  
	 Month C Index Value
	  	$	192.00	  
		  	  
	  
	 
	 Average Index Value
	  	$	178.67	  

 (Typical Analysis S02 - Quarterly Average Value S02) X (Quarterly Average Value BTU) X (quarterly tonnage) X (average index value) / 1,000,000 = adjustment 

(0.80 - 0.95) X (13,000) X (250,000) X (179.00) / 1,000,000 = -$87,101.625 

  
 31 

 APPENDIX A 
 SOURCE AREA AND AUTHORIZED SOURCES 
  

											
	 Permit No.
	  	 Mine Name
	  	 Coal Seam
	  	 TVA Plant
	  	Max. % Allowed in Blends	 
	 889-5014
	  	Parkway	  	#9	  	Paradise	  	 	100	  
		  		  		  	Cumberland	  	 	100	  
		  		  		  	Widows Creek	  	 	100	  
					
	 892-0108
	  	Kronos	  	#9	  	Paradise	  	 	100	  
		  		  		  	Cumberland	  	 	100	  
		  		  		  	Widows Creek	  	 	100	  
		  		  		  	Kingston	  	 	100	  

  
 32

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00221-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00221-of-00352.parquet"}], [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00221-of-00352.parquet"}], [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00221-of-00352.parquet"}], [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00221-of-00352.parquet"}]]