Document:

EX-10.2

 EXHIBIT 10.2 
 CONFIDENTIAL PORTIONS OMITTED 
  

	
	 Counterfeit Deterrence System

Development and License Agreement

 Table of Contents: 

 

							
	1.	 	DEFINITIONS AND PRINCIPLES OF INTERPRETATION	  	 	3	  
			
	2.	 	SCOPE OF THE SERVICES	  	 	11	  
			
	3.	 	PROGRAM MANAGEMENT	  	 	13	  
			
	4.	 	DELIVERABLES	  	 	16	  
			
	5.	 	RESPONSIBILITIES OF THE CBCDG	  	 	17	  
			
	6.	 	PRICE AND PAYMENT	  	 	18	  
			
	7.	 	CHANGE MANAGEMENT	  	 	20	  
			
	8.	 	INTELLECTUAL PROPERTY MATTERS	  	 	22	  
			
	9.	 	INTELLECTUAL PROPERTY INDEMNIFICATION	  	 	24	  
			
	10.	 	REPRESENTATIONS AND WARRANTIES OF DIGIMARC	  	 	27	  
			
	11.	 	REPRESENTATIONS AND WARRANTIES OF THE BIS	  	 	29	  
			
	12.	 	CONFIDENTIALITY	  	 	29	  
			
	13.	 	AUDIT AND INSPECTION	  	 	32	  
			
	14.	 	DISPUTE RESOLUTION	  	 	33	  
			
	15.	 	TERM AND TERMINATION	  	 	33	  
			
	16.	 	FORCE MAJEURE	  	 	36	  
			
	17.	 	NOTICES	  	 	36	  
			
	18.	 	MISCELLANEOUS PROVISIONS	  	 	37	  

 ** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.

 Counterfeit Deterrence System 

Development and License Agreement 
 This Counterfeit Deterrence System Development and License Agreement (the “Agreement”) is made 
 Between 
 DIGIMARC CORPORATION, a corporation incorporated under the laws of Oregon and
having its head office at 9405 SW Gemini Drive, Beaverton, Oregon, U.S.A. 97008 (“Digimarc”) 
 and 

BANK FOR INTERNATIONAL SETTLEMENTS, created pursuant to The Hague Agreements of January, 1930 having its head office at Centralbahnplatz 2,
CH-4051 Basel, Switzerland (“BIS”) 
 Recitals 
 WHEREAS: 
 Effective 1 January 1999, the predecessor to
Digimarc (then also known as Digimarc Corporation and subsequently merged into L-1 Identity Solutions Inc. in 2008) and the BIS entered into an agreement entitled the “Counterfeit Deterrence System Development and License Agreement.”

 WHEREAS: 
 On 14 March 2000, 28 December 2001, 1 January 2002 and 1 January 2004, the predecessor to Digimarc and the BIS entered into Amendments to the Counterfeit Deterrence System Development
and License Agreement (hereinafter the First, Second, Third and Fourth Amendments). On 18 August 2008, the BIS consented to assignment of the Agreement of 1999 and its amendments to Digimarc. 

WHEREAS: 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	2	 	Confidential

 The parties agreed to restate the Counterfeit Deterrence System Development
and License Agreement to include the First, Second, Third and Fourth Amendments into a new agreement and to make additional amendments. The restated and revised agreement was effective from 1 October 2009 (the “2009
Agreement”). 
 WHEREAS: 
 The parties wish to renew and extend this Counterfeit Deterrence System Development and License Agreement by entering into this renewal and extension agreement effective 1 January 2013. 

WHEREAS: 
 The parties have agreed that all Services performed prior to 1 January 2013 shall be governed by the previous versions of this Development and License Agreement in effect at the time of those
Services. 
 NOW THEREFORE: 
 Inconsideration of the promises and covenants set out in the Agreement and other good and valuable considerations, the receipt and adequacy of which are acknowledged by each of the parties, the parties
agree as follows: 
  

	1.	DEFINITIONS AND PRINCIPLES OF INTERPRETATION 

  

	1.1	Definitions – Whenever used in this Agreement, the following words and terms shall have the meanings set out below: 

“Agreement” means these articles of agreement, including the Schedules, and those documents as specified or referenced
in this Agreement as forming part of the Agreement, all as may be amended from time to time; 
 “Allowable
Cost” means a cost of the kind identified in Schedule F; 
 “Arbitration Agreement” means the
agreement attached as Schedule G; 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	3	 	Confidential

 “BIS Technology” means that technology that the BIS has the right to
license, including (a) [**], that the BIS licences to Digimarc on the terms set out in clause 8.1 to use, design or implement the CDS and all Intellectual Property Rights in that licensed [**]; 

“Business Day” means a day on which both the BIS and Digimarc are open for business at their respective addresses noted
above; 
 “CBCDG” means a committee of representatives from various [**] called “Central Bank Counterfeit
Deterrence Group”, previously known as “[**]”; 
 “CBCDG Contract Authority” means the chairman
of the CBCDG Executive Committee; 
 “CBCDG Project Director” means the project director appointed by the CBCDG
Contract Authority from time to time on notice to the Digimarc Contract Authority; 
 “CBCDG Project Office”
means the project office established by the CBCDG Contract Authority, or its staff as the case may be, and that is responsible for the oversight of the overall relationship among the BIS, the CBCDG, the [**] the CDS Technology, and Digimarc and for
the key day-to-day contract management; 
 “CBCDG Task” has the meaning assigned to it by clause 5.1;

 “CDS Technology” collectively, means whatever of the BIS Technology, the Digimarc Technology and the Project
Technology is incorporated into the CDS; 
 [**] 

“Confidential Information” means information disclosed during the Term of this Agreement in any form which, if disclosed
in tangible form, is labelled “Confidential”, “Proprietary” or with a similar legend, or if disclosed orally is information that by its nature would be understood to be confidential to the Discloser; 

“Contract Authority” means either the CBCDG or Digimarc Contract Authority, as the context requires; 

“Counterfeit Deterrence System” or “CDS” or “System” means a system for [**] that
includes [**]. The System incorporates means for [**]; 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	4	 	Confidential

 “Deliverable” means a product, document or tool to be delivered by Digimarc
identified in a Statement of Work; 
 “Dependency” means any of the following dependencies of Digimarc on [**]
and their employees, agents, representatives and subcontractors: 

	 	(a)	performing a task upon which Digimarc’s performance of any part of the Services is dependent; 

	 	(b)	timely providing to Digimarc the relevant technical information, [**]; 

	 	(c)	timely returning/negotiating [**], documents of understanding as necessary to protect Digimarc or BIS intellectual property; 

	 	(d)	having attendance of the relevant [**] employees or consultants at key briefings and review meetings; and 

	 	(e)	such dependencies as are expressly identified in a Statement of Work; 

 “Device” means any device in which the [**] device; 

“[**]” means the [**] of a [**]; 
 “Digimarc Contract Authority” means the individual designated by Digimarc in writing to the CBCDG Contract Authority from time to time; 

“Digimarc Project Director” means the Project Director appointed by the Digimarc Contract Authority in accordance with
the provisions of clause 3.3; 
 “Digimarc Technology” means: 

 

	 	(a)	the technology partially described in Schedule B developed or owned by Digimarc prior to 1 January 1999 to the extent that it forms part of the CDS;

	 	(b)	all Improvements to the technology described in (a) made by or on behalf of Digimarc other than under this Agreement to the extent that they form part of the CDS;

	 	(c)	all Improvements to the technology described in (a) made by or on behalf of Digimarc under this Agreement to the extent that they relate to or form part of the
CDS; and 

	 	(d)	all Intellectual Property Rights in all such technology and Improvements; 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	5	 	Confidential

 “Digital Watermark” refers to [**] (including [**]) that are [**] from [**]
by [**] of [**], which [**] of [**] and yet do not significantly [**] from the aesthetics of the [**] or [**] thereby. Examples include: 
  

	 	(a)	generally imperceptible changes to [**] or placement in [**]; 

	 	(b)	[**] of a substrate, where the [**] substantially uniform to human touch; 

	 	(c)	slight localized changes to [**] or [**] of a printed document; 

	 	(d)	slight changes to [**]; or 

	 	(e)	[**] of substantially [**]; 

“Discloser” means a party which has disclosed or otherwise made available its Confidential Information to the other
party; 
 “DLA Labour Costs” means the labour costs defined in Schedule F; 

“DLA Labour Rates” means the rates for Services set in accordance with Schedule F; 

[**] 

“Effective Date” means 1 January 2013; 
 [**] 
 “[**] Support Services” means Integration Support,
Training and conducting Verification Tests; 
 “Escrow Agent” means a custodian appointed by the CBCDG Contract
Authority; 
 “Escrowed Materials” means any and all materials deposited or to be deposited by Digimarc with
the Escrow Agent under this Agreement including the Improvements pertaining to the CDS Technology which shall include the following: 
  

	 	(a)	all Deliverables and work completed by Digimarc (including all [**], [**] and [**] deliverables, supporting documentation, tools and any other product created by
Digimarc) in support of delivery of the Services since the last escrow deposit; 

	 	(b)	details of the deposit including: full name and version details, number of media items, media type and density, file or archive format, list or retrieval commands,
archive hardware and operating system details; 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	6	 	Confidential

	 	(c)	name and functionality of each module or application of the Escrowed Materials; 

	 	(d)	names and versions of development tools; 

	 	(e)	documentation describing the procedures for building, compiling, executing and using the software which forms part of the Escrowed Materials (e.g., technical notes,
user guides); 

	 	(f)	hardcopy directory listings and tables of the contents of the computer media, manuals and other materials; and 

	 	(g)	name and contact details of employee(s) with knowledge of how to maintain and support the Escrowed Materials; 

[**] 

“Improvement” means any change in the CDS Technology made by or at the direction of Digimarc after 1 January 1999
which enhances, whether by improvement, enhancement, correction, addition or otherwise, the properties, characteristics or manufacture of the CDS and any change to the CDS Technology and/or the [**] made by any [**] in connection with the [**] of
the CDS by any [**] that Digimarc has rights in, including customization, improvements, enhancements, corrections, and changes to the [**] so that it can interface properly to a [**]; 

“Integration Support” means the consulting and programming services to be provided by Digimarc as requested by a [**] to
assist the [**] to ensure that the [**] is [**] in a [**]; 
 “Intellectual Property Rights” means all
intellectual property rights existing now and in the future including trade secrets, trademarks, copyright, database rights, know-how, topographies, patents and patent applications; 

“[**]” means an entity responsible for [**]; 
 “[**]” means the template license agreement with that name agreed upon between the CBCDG and Digimarc, as amended from time to time; 

“[**]” means the template license agreement with that name agreed upon between the CBCDG and Digimarc, as amended from
time to time; 
 “Key Personnel” mean those personnel identified in clause 3.5; 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	7	 	Confidential

 “[**]” means an [**] licensed by Digimarc pursuant to clause 2.2;

 “[**]” means an entity that is authorized by a [**] and/or the CBCDG Contract Authority and [**] containing
[**] pursuant to clause 2.3; 
 “[**]” means the template license agreement agreed upon between the CBCDG and
Digimarc, as amended from time to time; 
 “Person” means any individual or other legal entity, including a
sole proprietorship, partnership, unincorporated association, unincorporated syndicate, unincorporated organization, trust, body corporate, or a natural person in the capacity of trustee, executor, administrator or other legal representative;

 “Plan Budget” means the document approved under clause 3.12 defining a minimum spend commitment for a
particular calendar year by the CBCDG, subject to clause 3.13; 
 “Planning Process” means the process for the
development of the Statements of Work and Roadmap as agreed to in writing between the CBCDG Project Office and Digimarc; 

“Pricing Formula” means the formula defined in Schedule F, clause 9; 

“[**]” means the template license agreement with that name agreed upon between the CBCDG and Digimarc, as amended from
time to time; 
 “[**]” means the template license agreement with that name agreed upon between the CBCDG and
Digimarc, as amended from time to time; 
 “Problem Report” means a report of a problem in a format agreed to
by the CBCDG Project Director and Digimarc; 
 “Project Director” means either the CBCDG or Digimarc Project
Director, as the context requires; 
 “Project Technology” means the technology described in Schedule C
developed by or on behalf of Digimarc under this Agreement after 1 January 1999, all Improvements to that technology or to the BIS Technology, and all Intellectual Property Rights in that technology and those Improvements; 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	8	 	Confidential

 “Properly Embedded” when used in reference to a [**] means that the [**] is
[**] in accordance with the written instructions provided with the [**] used to [**] and is capable of passing the Verification Test; 
 “Recipient” means a party to which the Confidential Information of the other party has been disclosed or otherwise made available; 

“Roadmap” means the rolling five year project and budget plan agreed to in writing by the CBCDG Contract Authority and
Digimarc and updated annually; 
 “Schedule” means a schedule to this Agreement; 

[**] 

“Security Requirements” means the requirements for physical security including electronic systems security set out in
Schedule D; 
 “Services” means the services required to be performed by Digimarc as set out in clause 2, and
other services reasonably necessary to comply with its obligations under this Agreement; 
 “SOW Budget” means
the amount approved under clause 3.11 defining a minimum spend commitment related to a Statement of Work for a particular calendar year by the CBCDG, subject to clause 3.13; 
 “Specifications” for the CDS or any part thereof means the technical specifications for the products and tools of the CDS or part thereof to be delivered or already accepted by the CBCDG
Project Director under this Agreement; 
 “Statement of Work” means the document that captures and defines the
work activities, deliverables and timeline Digimarc will execute against in performance of specified work developed in accordance with the Planning Process; 
 “Term” means the period commencing on the Effective Date and ending on 31 December 2024; 
 “Training” means the training in the use and operation of the [**] described in Schedule E; and 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	9	 	Confidential

 “Verification Test” means a test or tests to determine if [**]. The
Verification Test is defined in the Verification Test procedure and is executed using the Verification Test tool. 
  

	1.2	Interpretation – in this Agreement: 

  

	 	1.2.1	unless otherwise specified, all references to money amounts are to the currency of the United States of America; 

 

	 	1.2.2	the use of words in the singular or plural, or with a particular gender, shall not limit the scope or exclude the application of any provision of this Agreement to such
Person or Persons or circumstances as the context otherwise permits; 

  

	 	1.2.3	whenever a provision of this Agreement requires an acceptance, approval or consent by a party to this Agreement and notice of such acceptance, approval or consent is
not delivered within the applicable time, then the party shall be conclusively deemed to have withheld the acceptance, consent or approval; 

  

	 	1.2.4	unless otherwise specified, the number of days within or following which any payment is to be made or act is to be done shall be interpreted to be continuous and shall
be calculated by excluding the day on which the period commences and including the day which ends the period and by extending the period to the next Business Day if the last day of the period is not a Business Day; 

 

	 	1.2.5	unless otherwise specified, the order of precedence for interpreting this Agreement shall be: 

 

	 	(a)	the terms of this Agreement, excluding Schedules; 

	 	(b)	the Schedules; 

	 	(c)	the Statement of Work; 

	 	(d)	as between the delivery schedules forming part of a Statement of Work, and other provisions for such Statement of Work, the delivery schedules shall take precedence;

  

	 	1.2.6	for greater certainty, a party or representative to which this Agreement grants the right to make a decision or determination in the sole discretion of the party or
representative is not required to act reasonably in making the decision or determination and no such decision or determination may be challenged by the other party under the Arbitration Agreement or otherwise; 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	10	 	Confidential

	 	1.2.7	the words “includes” or “including” will be construed as meaning “includes without limitation” and “including without
limitation” as the case may be; and 

  

	 	1.2.8	a clause or Schedule, unless the context requires otherwise, is a reference to a clause to, a Schedule of, or a paragraph of a Schedule to, this Agreement, as amended
from time to time in accordance with this Agreement. 

  

	1.3	Applicable Law – The Agreement and all amendments thereto shall be construed in accordance with the laws of England to the exclusion of its rules of
conflicts of laws. 

  

	1.4	Schedules – The Schedules to this Agreement, listed below, are an integral part of this Agreement. 

			
	Schedule	  	Description
	Schedule A	  	System Description
	Schedule B	  	Digimarc Technology
	Schedule C	  	Project Technology
	Schedule D	  	Security Requirements
	Schedule E	  	Training
	Schedule F	  	Allowable Costs
	Schedule G	  	Arbitration Agreement

  

	2.	SCOPE OF THE SERVICES 

  

	2.1	Digimarc shall provide the Services as stated in the Statements of Work. 

  

	2.2	Digimarc shall, when requested by the CBCDG Contract Authority, make an irrevocable offer to an [**] to grant the [**] a [**] to the relevant CDS Technology in
connection with the banknotes of the [**] on terms no less favourable to the Issuing Authority than those set out in the [**] for CBCDG Members or the [**], as applicable. 

 

	2.3	Digimarc shall, when requested by the CBCDG Contract Authority and/or [**]: 

 

	 	(a)	make an irrevocable offer to [**] designated by the CBCDG Contract Authority and/or [**] a [**] to the relevant CDS Technology in connection with [**] of a [**], on
terms no less favourable to the [**] than those set out in the [**] as applicable; and 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	11	 	Confidential

	 	(b)	deliver the relevant CDS Technology to the [**] referred to above at no charge and provide the Training to the [**] for the charges to the [**] described in clause 2.6
within thirty (30) Business Days after the [**] acceptance of the offer to [**], or at such other times as may be agreed between Digimarc and the [**]. 

 

	2.4	No later than sixty (60) Business Days after every written request made by a [**] during the Term, Digimarc shall provide Integration Support to the [**] on a date
or dates agreed between Digimarc and the [**] for the charges described in clause 2.6. 

  

	2.5	No later than twenty (20) Business Day after every written request made by a [**] during the Term, Digimarc shall conduct Verification Tests of [**] on a date or
dates agreed between Digimarc and the [**], as the case may be, for the charges specific in clause 2.6. 

  

	2.6	The amount charged by Digimarc to the [**] for [**] Support Services will be in accordance with the Allowable Costs. 

 

	2.7	Digimarc shall continue to provide support to [**] for the two (2) most recently released versions of the [**] unless the CBCDG Project Director instructs
otherwise. 

  

	2.8	Digimarc [**] the relevant CDS Technology to all [**] at the request of the CBCDG Project Director on terms no less favourable to the [**] than those set out in the
[**]. 

  

	2.9	Digimarc shall continue to support all deployed versions of the [**] and [**] as instructed by the CBCDG Project Director. 

 

	2.10	The BIS hereby grants Digimarc a [**] the BIS may have or acquire under clause 8.2 of the Agreement. 

 

	2.11	Digimarc shall be responsible for compliance with laws and regulations governing export from the United States. As between Digimarc and the CBCDG Contract Authority,
the CBCDG Contract Authority shall be responsible for advising those using the CDS on compliance with laws and regulations governing export from their countries and on compliance with United States law concerning re-export. Upon request from the
CBCDG Project Director, Digimarc shall provide assistance to support the CBCDG Project Director advising such users of the CDS on compliance with laws and regulations governing export from their countries and on compliance with United States law
concerning re-export. Costs that Digimarc incurs in compliance with this clause 2.11 are an Allowable Cost. 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	12	 	Confidential

 [**] 
  

	2.12	Digimarc acknowledges and confirms the BIS’ right to enforce clauses 2.2, 2.3 and 2.8 by an application for specific performance or otherwise.

  

	2.13	Digimarc shall at all times comply, and shall ensure that its employees, agents and subcontractors comply, with the Security Requirements. 

 

	2.14	The CBCDG Project Office and Digimarc shall develop a plan that establishes a procedure which, upon notice of termination of this Agreement, facilitates the orderly
winding down of the Services or the orderly, effective and efficient transition of the operational capability, knowledge of the Services and the responsibility for the provision of the Services, from Digimarc to an alternate supplier
(“Termination Assistance Plan” or “TAP”). The TAP shall be reviewed annually and updated as required. The CBCDG Contract Authority agrees to pay for such assistance as provided under the TAP. 

 

	3.	PROGRAM MANAGEMENT 

  

	3.1	The BIS designates the CBCDG Contract Authority, the CBCDG Project Director and the CBCDG Project Office as its agents to carry out the responsibilities designated to
each of them respectively throughout this Agreement. They shall each have only the powers specified in the respective provisions of this Agreement. The BIS hereby agrees to procure the performance of any obligations that are expressed to be
performed by any of the CBCDG, the CBCDG Contract Authority, the CBCDG Project Director or the CBCDG Project Office. 

  

	3.2	The CBCDG Project Director shall be responsible for coordinating fulfillment by the BIS of its obligations under this Agreement and directing Digimarc in respect of
prioritizing effort and timing of Services in relation to any [**] and/or [**] in accordance with the agreed upon Statement of Work and changes thereto. Except as expressly set out in this Agreement, the CBCDG Project Director shall have no
authority to amend this Agreement, approve payments or approve or accept Deliverables or other Services or proposals on behalf of the BIS. 

  

	3.3	Digimarc shall designate a responsible individual with adequate authority and competence as the Digimarc Project Director. The Digimarc Project Director shall be
responsible for coordinating the performance of the Services by Digimarc including serving as project leader and primary interface with the CBCDG, but shall have no authority to agree to an amendment of this Agreement on behalf of Digimarc.

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	13	 	Confidential

	3.4	The respective Project Directors or Contract Authorities may from time to time appoint one or more persons to represent him or her on prior written notice to the other
Project Director or Contract Authority. 

  

	3.5	The CBCDG Project Director and Digimarc Project Director shall agree on the list of Key Personnel whose knowledge and skill set make them critical to the delivery of
the Services. The list of Key Personnel shall be sent to the CBCDG Contract Authority annually by 31 December. If it becomes necessary for Digimarc to provide substitute or add Key Personnel for any reason, the CBCDG Contract Authority must approve
such Key Personnel in advance, which approval shall not be unreasonably withheld. Digimarc shall, at Digimarc’s cost, train the replacement Key Personnel about the job specifics so the replacement personnel shall be able to perform the Services
of the replaced Key Personnel at the particular state the Services had reached when the personnel change occurred. 

  

	3.6	Digimarc shall replace within a reasonable time under the circumstances any of its employees or authorized subcontractors engaged in fulfilling its obligations under
this Agreement, including its Project Director, whose removal is required by the CBCDG Contract Authority, provided that the CBCDG Contract Authority specifies reasonable cause for such removal in writing. 

 

	3.7	Digimarc undertakes that all personnel assigned to perform the Services shall be employees or a non-material subcontractor of Digimarc. Digimarc shall provide
reasonable prior written notice of its intent to use a material subcontractor. The CBCDG Project Director shall have the right to approve all material subcontractors, which approval shall not be unreasonably withheld. Digimarc undertakes that it
shall obtain from each subcontractor prior to permitting that subcontractor to do any part of the Services a written undertaking that all Intellectual Property Rights in any work developed by that subcontractor while providing the Services shall
vest absolutely in Digimarc upon the date of creation. Digimarc shall remain responsible for any obligations which are performed by a subcontractor and for the conduct of subcontractors as if they were the acts or omissions of Digimarc.

  

	3.8	 Digimarc shall report on progress of the Services in the format and with the frequency directed in writing by the CBCDG Contract Authority. Digimarc
will attend such review meetings as requested by the CBCDG Project Director. There will be at least six (6) such review meetings per year or as otherwise agreed by the parties to review technical, planning and resource matters. Each such
meeting will last no more than two (2) days 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	14	 	Confidential

	 	 
unless otherwise agreed upon in advance and will be held at a mutually agreeable date and location. At least half of the review meetings will be held at Digimarc. Digimarc will also provide a
presentation for the CBCDG [**] on development and [**] progress at least once per year if requested by the CBCDG Project Director. 

  

	3.9	In the event that it becomes evident to a Project Director that a failure or delay to perform in accordance with a party’s obligations under this Agreement will
result in a material impact on the completion of the Services in accordance with the applicable Statement of Work, then the relevant Project Director shall immediately bring the issue to the attention of the other Project Director.

  

	3.10	As of the Effective Date, the CBCDG Contract Authority shall have approved the 2013 Statement of Work and the 2014 Plan Budget. 

 

	3.11	The Statement of Work and associated SOW Budget for the next calendar year (starting with 2014) shall be prepared by Digimarc in collaboration with the CBCDG Project
Director and provided to the CBCDG no later than 31 May of each year or such later date as agreed between the CBCDG Project Director and Digimarc. The CBCDG Contract Authority shall, by 30 June of each year or such later date as agreed
between the CBCDG Project Director and Digimarc, notify Digimarc in writing of the CBCDG’s approval of the Statement of Work and associated SOW Budget for the next calendar year. 

 

	3.12	The Plan Budget for the calendar year following the next calendar year (starting with 2015) shall be prepared by Digimarc in collaboration with the CBCDG Project
Director and provided to the CBCDG no later than 31 May of each year or such later date as agreed between the CBCDG Project Director and Digimarc. The CBCDG Contract Authority shall, by 30 June of each year or such later date as agreed
between the CBCDG Project Director and Digimarc, notify Digimarc in writing of the CBCDG’s approval of such Plan Budget for the calendar year following the next calendar year. The Plan Budget for any given calendar year shall be the basis for
creating the SOW Budget for that same calendar year. 

  

	3.13	If Digimarc is ready, willing and able to provide the Services at the level of such SOW Budget amounts and such Plan Budget amounts and is not otherwise in material
breach of this Agreement, the CBCDG Contract Authority shall pay Digimarc at least such SOW Budget amounts and such Plan Budget amounts for the relevant years. In the event of any termination of the Agreement, the terms of clause 15 shall take
precedence over this clause. 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	15	 	Confidential

	3.14	The total value of the Services set out in the Statement of Work for any given year must be greater or equal to the initial approved Plan Budget for that year.

  

	3.15	The CBCDG Project Office and Digimarc shall hold planning meetings in accordance with the Planning Process as needed to review the scope and status of current and
planned projects under the Statement of Work and Roadmap relative to the schedule, expenditures and budgets and to establish Statements of Work for subsequent periods. 

 

	3.16	The CBCDG Project Office and Digimarc shall meet at least once in each calendar year to discuss [**] and similar issues related to the development, [**] and [**] of the
CDS. If both parties agree that this meeting is not required in any given year, the meeting will not be held. 

  

	4.	DELIVERABLES 

  

	4.1	Deliverables shall be approved by the CBCDG Contract Authority in accordance with the timing and criteria set out in the relevant Statement of Work.

  

	4.2	Where a Deliverable depends upon acceptance and Digimarc fails to produce a Deliverable acceptable to the CBCDG Contract Authority in accordance with the acceptance
criteria set out in the applicable Statement of Work then the CBCDG Contract Authority may, in its sole discretion, by written notice to Digimarc, either: 

 

	 	(a)	allow additional time for Digimarc to produce a Deliverable acceptable to the CBCDG Contract Authority, whereupon the time for completion of all other Deliverables
which depend on the acceptance shall automatically be extended by one day for each additional day or such other period as may be agreed in writing between the respective Contract Authorities; or 

 

	 	(b)	cancel any further work on the Deliverable and all Deliverables which depend on the acceptance, whereupon the Statement of Work which provides for the cancelled work or
Deliverables which depend on the acceptance shall be deemed to be amended to exclude them. 

  

	4.3	Digimarc shall not be responsible to the extent any failure by Digimarc to perform the Services in accordance with this Agreement is directly attributable to: a) a
delay to perform any CBCDG Task applicable to the affected part of the Services; b) a Dependency applicable to the affected part of the Services not being fulfilled by a [**]; or c) a force majeure event (as defined in clause 16.1).

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	16	 	Confidential

	4.4	If any version of the [**] fails to meet the Specifications for that version within one (1) year of the date of acceptance thereof by the CBCDG Contract Authority,
and such failure could not have been discovered by the CBCDG Contract Authority using reasonable diligence during the acceptance procedure for that version, then Digimarc shall, at its own expense, within sixty (60) days after receipt of a
Problem Report from the CBCDG Project Director or such other period as the CBCDG Project Director may agree, rectify the failure and at the direction of the CBCDG Project Director provide a corrected [**] to which Digimarc had previously provided
the [**]. 

  

	4.5	If any version of a [**] provided by Digimarc to any Person during the Term for incorporation into any Device, fails to meet the relevant Specifications within one
(1) year of the date of acceptance thereof by the CBCDG Contract Authority, and such failure could not have been discovered by the CBCDG Contract Authority using reasonable diligence during the acceptance procedure for that version, then
Digimarc shall, at its own expense, within sixty (60) days after receipt of written notice of a Problem Report from the CBCDG Project Director or such other period as the CBCDG Project Director may agree, rectify the failure and at the
direction of the CBCDG Project Director provide [**] to all Persons to which Digimarc had previously provided such a [**]. 

  

	5.	RESPONSIBILITIES OF THE CBCDG 

  

	5.1	The CBCDG Project Director shall ensure that the CBCDG performs all tasks assigned to it in a Statement of Work by the dates set out therein (herein referred to as the
CBCDG Tasks) provided that Digimarc has provided the CBCDG Project Director with reasonable notice that there is a Digimarc action that is dependent on that CBCDG Task. 

 

	5.2	Unless otherwise expressly set out in this Agreement, the CBCDG Contract Authority or the CBCDG Project Director shall respond in writing within ten (10) Business
Days to every written request for consent required by this Agreement received from Digimarc. 

  

	5.3	 If there is a delay in complying with any of the obligations under clauses 5.1 or 5.2 for any reason not attributable to Digimarc, and such delay will
cause a delay in the completion and delivery by Digimarc of any Services, then Digimarc shall reasonably promptly advise the CBCDG Project Director of the impact of the delay. The time for completion of the Services and all subsequent Services
dependent thereon, shall then be extended automatically by one day for each day of delay or such other period as may be agreed in writing between the respective Contract Authorities. If Digimarc suffers

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	17	 	Confidential

	 	 
increased costs by reason of such delay, other than a delay due to a force majeure event (as defined in clause 16.1), such costs reasonably and necessarily incurred by Digimarc shall be borne by
the CBCDG Contract Authority. Digimarc shall make every reasonable effort to reassign staff and otherwise mitigate the increased costs associated with such a delay. If the delay is due to a force majeure event, such costs shall be borne equally by
the CBCDG Contract Authority and Digimarc. If there are any additional costs to be borne by the CBCDG Contract Authority otherwise than as agreed under clause 6 of this Agreement, Digimarc shall reasonably promptly notify the CBCDG Contract
Authority of such and the CBCDG Contract Authority shall either approve such costs and/or request a change to the Services under clause 7 of this Agreement. Such change request shall ask Digimarc to describe the effect the costs and delay under this
clause 5.3 will have on the applicable Statements of Work. If after Digimarc describes the effect the costs and delay under this clause 5.3 will have on the applicable Statements of Work, the CBCDG Contract Authority requests such a change, the
Statements of Work shall be amended so that Digimarc remains within the previously approved SOW Budget. This clause 5.3 sets forth Digimarc’s only remedy for a delay by the CBCDG in complying with any such obligation.

  

	6.	PRICE AND PAYMENT 

  

	6.1	The BIS designates the CBCDG Contract Authority as its agent to make all payments owed by the BIS under or in connection with this Agreement. Digimarc shall notify the
BIS if any payment is not received within thirty (30) days of when such payment is due. 

  

	6.2	Subject to the limits set out in this Agreement and unless otherwise expressly set out herein, the CBCDG Contract Authority shall reimburse Digimarc for all the
Allowable Costs reasonably and properly incurred by Digimarc during each calendar month to perform the Services. Digimarc shall send its invoice to the CBCDG Contract Authority monthly in arrears for such Allowable Costs. Each invoice shall specify
the Expenses (as defined in Schedule F) incurred and the time spent by the staff and sub-contractors of Digimarc in performing the Services and shall give a breakdown of the Allowable Costs. 

 

	6.3	The CBCDG Contract Authority shall pay Digimarc each amount which is owed Digimarc under this Agreement no later than thirty (30) days after the later of the
payment due date and the date on which the CBCDG Contract Authority receives a detailed and correct invoice for the amount. 

  

	6.4	 For a period of five (5) years following their creation, Digimarc shall maintain proper, up-to-date, accurate and complete books, records and
other documentation substantiating 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	18	 	Confidential

	 	 
the Allowable Costs invoiced under this Agreement including time sheets showing the hours spent on each task which forms part of the Services and receipts for all Expenses. Digimarc shall produce
such books, records and documentation to the CBCDG Project Office or its representatives for inspection and copying at Digimarc’s premises (with the right to take such copies from Digimarc’s premises as long as Digimarc is notified in
writing what copies are removed from Digimarc’s premises and the copies are handled by the CBCDG Project Office or its representative in accordance with the confidentiality obligations under clause 12) at all reasonable times on request by the
CBCDG Project Director. 

  

	6.5	Except as otherwise expressly provided in this Agreement, the CBCDG Contract Authority shall pay Digimarc all sales, use, goods and services or other similar taxes
levied by any government in the [**] which Digimarc is obliged to collect and remit to such government(s) in connection with any amount paid under this Agreement. 

 

	6.6	Digimarc is responsible for, and shall indemnify the BIS against, and hold the BIS harmless from, the payment of all taxes levied by any government on or in respect of
Digimarc’s income and any amounts required by law to be paid in respect of social benefits for Digimarc’s employees relating to or arising out of the performance of the Services by Digimarc. If required by law, the BIS shall deduct all
such taxes and amounts from the amounts otherwise payable to Digimarc and remit them to the appropriate authorities. 

  

	6.7	The BIS may set off against any amount which the BIS owes Digimarc under or in connection with this Agreement any amount which Digimarc owes the BIS under or in
connection with this Agreement including damages for breach. 

  

	6.8	 Any equipment or software [**] purchased for over [**] as an Allowable Cost shall be owned by the BIS or another entity designated by the CBCDG
Contract Authority and shall be held in trust by Digimarc. Digimarc shall ensure that the BIS or the designated entity is identified on such [**] and [**] as the owner. Unless such [**] or [**] needs to be used in a manner that it was not designed
for and the CBCDG Contract Authority is made aware of such need, Digimarc shall, at its own risk, use such [**] or [**] in a reasonably careful and proper manner and in accordance with all operating instructions. In any event such [**] and [**]
shall be used by Digimarc solely for the provision of the Services. Upon termination of this Agreement and at the request of the CBCDG’s Project Director, Digimarc shall promptly deliver such [**] and [**] to the CBCDG Project Office at the
CBCDG’s expense. Such [**] and [**] shall be returned in the same condition as originally received by Digimarc, reasonable wear and tear excepted. 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	19	 	Confidential

	 	 
If, however, the [**] or [**] needs to be used in a manner that it was not designed for and the CBCDG Project Director is made aware of such need, then such [**] and [**] shall be returned
“as is.” The CBCDG Contract Authority shall reimburse Digimarc for any unrecovered costs of such [**] or [**] (i.e. costs not recovered through depreciation charges), subject to receipt of a correct and properly due invoice.

  

	6.9	DLA Labour Rates as set out and adjusted in accordance with Schedule F shall be no greater than the then-current rates charged to Digimarc’s most favored
customers, [**]. 

  

	6.10	If an approved Plan Budget for any calendar year is at least [**]), but does not amount to at least [**]), 

 

	 	(a)	Digimarc can start a review of the DLA Labour Rates for all DLA labour positions set out in Schedule F according to the agreed upon Pricing Formula. The review will be
completed within three months of the day Digimarc gives the CBCDG notice that it is initiating a review under Schedule F. Any adjustment to the DLA Labour Rates under this review will be effective on the January 1 of the year that the lower
Plan Budget would be effective. The DLA Labour Rates for that same January 1 date shall also be adjusted in accordance with the indexation formula of clause 7 of Schedule F; and 

 

	 	(b)	The CBCDG Contract Authority shall pay Digimarc all of its actual and reasonable costs incurred in connection with the reduced Plan Budget including:

  

	 	(i)	third party contract termination costs; 

	 	(ii)	employee re-deployment or termination costs including severance, outplacement, benefits, acceleration of stock compensation, employer paid payroll taxes; and

	 	(iii)	accounting, legal and travel costs associated with the reduced Plan Budget and related negotiations. 

Digimarc shall use commercially reasonable efforts to mitigate all such costs. 

 

	7.	CHANGE MANAGEMENT 

  

	7.1	The CBCDG Project Director or Digimarc may request a change to the Statements of Work from time to time by submitting a request in writing to the other party’s
Project Director. Any such request shall indicate the nature of the new work to be performed in a form sufficient for Digimarc to investigate the effect of the change. 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	20	 	Confidential

	7.2	On making such a change request or within ten (10) Business Days after receiving a change request from the CBCDG Project Director, Digimarc shall inform the CBCDG
Project Director of the amount, if any, which Digimarc intends to invoice to investigate the effect the change will have on the applicable Statements of Work and the Allowable Costs for the applicable Statements of Work. 

 

	7.3	Within ten (10) Business Days after receiving the written authorization of the CBCDG Project Director to conduct the investigation of a change, or such longer
period as may be authorized by the CBCDG Project Director, Digimarc shall report to the CBCDG Project Director, in writing, on the results of the investigation. 

 

	7.4	Within ten (10) Business Days after the CBCDG Project Director receives the report and, if the change will not increase the approved SOW Budget for a given year as
set out in the approved Statements of Work, then the CBCDG Project Director shall notify Digimarc whether or not the change is authorized. If the change will increase the approved SOW Budget for a given year as set out in the approved Statements of
Work, then the CBCDG Contract Authority must notify Digimarc whether or not the change is authorized. 

  

	7.5	The Statements of Work shall be updated quarterly to reflect all authorized changes to properly state the new obligations of Digimarc. If both parties agree that an
update to the Statement of Work is not required for any given quarter, none shall be provided. 

  

	7.6	Digimarc shall not implement any change to the Services until the change is authorized in writing by the CBCDG Project Director or the CBCDG Contract Authority, as set
out in clause 7.4. Digimarc shall implement any change directed and authorized pursuant to clause 7.4 provided: 

  

	 	(a)	the change is technically feasible and is within the capabilities of Digimarc; 

 

	 	(b)	the costs associated with such change identified by Digimarc in its investigative report and approved under clause 7.4 as part of the approval of the change are borne
by the CBCDG Contract Authority; and 

  

	 	(c)	Digimarc is given commensurate relief in the manner and to the extent as specified in the authorized change from prior commitments under the Statements of Work.

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	21	 	Confidential

	7.7	Pending receipt of a written authorization from the CBCDG Project Director or the CBCDG Contract Authority, Digimarc shall proceed with the Services in accordance with
the approved Statements of Work. 

  

	8.	INTELLECTUAL PROPERTY MATTERS 

  

	8.1	The BIS grants to Digimarc a [**] such BIS Technology which is incorporated into the CDS or needed by Digimarc in order to comply with its obligations under this
Agreement and to sublicense the same in any license agreement entered into by Digimarc as directed or permitted by the CBCDG Contract Authority under this Agreement and for no other purpose. 

 

	8.2	The BIS and Digimarc agree to renew and extend the [**] to the BIS as set out at clauses 8.4-8.11 of the 2009 Agreement, in the manner set out in this clause 8.
Accordingly, Digimarc hereby renews and extends the [**] to the BIS of the [**] the Digimarc Technology and the Project Technology, and all Improvements thereto, and [**] of the Digimarc Technology and the Project Technology and such Improvements to
other Persons, for the purposes of: 

  

	 	(a)	[**], the [**] and any such component thereof, and making the [**] and any component available to others; and 

 

	 	(b)	[**]; 

 [**]. 

The [**] to the BIS and renewed and extended by this clause 8.2 applies to Digimarc Technology and the Project Technology and all
Improvements existing on or before the effective date of this Agreement and created on an on-going basis under any subsequent Statements of Work approved under this Agreement. [**] 

[**], including [**]. For greater certainty, the uses permitted by the license are limited to [**]. 

The [**] to the BIS does not permit any other uses, [**]. 

 

	8.3	The [**] to the BIS and described in clause 8.2 has effect in respect of each specific item of Digimarc Technology, Project Technology or Improvements created as set
out in clause 8.2 on the earliest of: 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	22	 	Confidential

	 	(a)	the date on which the CBCDG Contract Authority pays Digimarc all sums properly due to Digimarc under this Agreement for the development of that specific item;

  

	 	(b)	sixty (60) days following the effective date of termination of this Agreement in accordance with the provisions of clause 15.2(a), (b), (d) or (e) unless
Digimarc demonstrates within such sixty (60) day period that, notwithstanding the occurrence of the events giving rise to the termination, Digimarc is willing and able to comply with its obligations under the Agreement; or

  

	 	(c)	the effective date of termination of this Agreement in accordance with the provisions of clauses 15.2(c), 15.2(f), 15.2(g), 15.3, 15.5 or 15.9.

  

	8.4	Nothing in this Agreement shall be construed to grant or create any broader license rights than those expressly granted by this Agreement. 

 

	8.5	From time to time during the Term, on no less than thirty (30) Business Days prior written notice by the CBCDG Project Director, Digimarc shall, at Digimarc’s
premises, present representatives of the Escrow Agent with all the Escrowed Materials, in any form, in Digimarc’s possession or control. The representatives may identify any or all of such material and Digimarc shall arrange, at the expense of
the BIS, for a complete, accurate and up-to-date copy of the selected material to be made and sent to the Escrow Agent within five (5) Business Days of the selection being made for deposit. All work to prepare and deliver the Escrow Materials
to the Escrow Agent will be Allowable Costs. 

  

	8.6	The CBCDG Contract Authority shall inform Digimarc within thirty (30) days after the end of each calendar quarter during the Term of all improvements relating to
(i) [**]; (ii) [**]; (iii) [**]; and (iv) any other part of the CDS, [**] the CBCDG [**], or caused or permitted to be made, as a result of access to and use of the Escrowed Materials or the Digimarc Confidential Information. The
CBCDG Contract Authority shall provide to Digimarc within a reasonable period of time following request, the information for those improvements requested by Digimarc in writing. 

 

	8.7	The BIS hereby grants to Digimarc a royalty-free, non-exclusive, non-transferable, worldwide license to use and license the improvements described in clause 8.6 and in
any patents thereon owned or otherwise licensable by the BIS. 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	23	 	Confidential

	8.8	For greater certainty, the obligations set out in clauses 8.6 and 8.7 shall not apply to any improvement which the CBCDG Contract Authority can demonstrate would have
been made irrespective of access to the Escrowed Materials or Digimarc Confidential Information. 

  

	8.9	The CBCDG Contract Authority shall take all reasonable steps to ensure that Persons to whom it allows access to the Escrowed Materials will be contractually bound in
accordance with terms substantially like those set forth in clauses 8.6, 8.7 and 8.8, granting rights in favour of Digimarc. 

  

	8.10	On the date on which the grant of the license to the BIS (as set out in clause 8.2) takes effect in respect of a specific item of Digimarc Technology, Project
Technology or Improvements, the CBCDG [**], copy and use the Escrowed Materials relating to such item. 

  

	9.	INTELLECTUAL PROPERTY INDEMNIFICATION 

  

	9.1		(a)	 The BIS shall provide Digimarc with prompt written notice of any claim, demand or action against the BIS based on an allegation that the
CDS, the Digimarc Technology or the Project Technology or any Improvements thereto or any part thereof, infringes any Intellectual Property Right of any Person (referred to below as a “Claim”). 

 

	 	(b)	Upon such notice, Digimarc shall at its own expense resolve any Claim, including settlements or litigation proceedings, and pay all costs associated with the resolution
of such Claim. 

  

	 	(c)	Any counsel hired to assist in the resolution of such Claim shall be selected by mutual agreement between the BIS and Digimarc. 

 

	 	(d)	Digimarc shall consult and work in cooperation with the BIS in connection with the resolution of any Claim, taking into account the BIS’ special status as an
international organization. 

  

	 	(e)	The BIS shall comply with all reasonable requests for assistance from Digimarc in connection with the settlement or defense of any Claim. 

 

	9.2	Notwithstanding any other provision of this Agreement to the contrary but subject to these clauses 9.1-9.3 (including the notice in clause 9.1(a)), Digimarc shall
indemnify the BIS against and save the BIS harmless from all loss, costs, liabilities including, for greater certainty an award of damages, and expenses and reasonable legal fees, arising from each Claim. The obligation set out in these clauses
9.1-9.3 shall not apply in respect of any settlement made by the BIS without the consent of Digimarc. 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	24	 	Confidential

	9.3	If the CDS, the Digimarc Technology or the Project Technology, or any Improvement thereto or part thereof is held to infringe, or if Digimarc believes that it is likely
to be held to infringe, any of the Intellectual Property Rights described in clause 9.1, Digimarc shall, in addition to its other obligations set out above, at its own expense either: 

 

	 	(a)	procure for the BIS the right to continue using the allegedly infringing materials; or 

	 	(b)	replace or modify the materials to the reasonable satisfaction of the BIS so that the materials are no longer infringing but remain functionally equivalent.

 Failing either of which result the BIS may, at its option, terminate this Agreement without prejudice to the
BIS’ other rights and remedies available in law, at equity or otherwise. 
  

	9.4	Digimarc shall provide the BIS with prompt written notice of any claim, demand or action against Digimarc based on an allegation that the BIS Technology or any part
thereof, infringes any Intellectual Property Right of any person (referred to below as a “BIS Technology Claim”). Digimarc shall comply with all reasonable requests for assistance from the BIS in connection with the settlement or defense
of any BIS Technology Claim. 

  

	9.5	Notwithstanding any other provision of this Agreement to the contrary, the BIS shall indemnify Digimarc against and save Digimarc harmless from all loss, costs,
liabilities including, for greater certainty an award of damages, and expenses and reasonable legal fees, arising from each BIS Technology Claim. The obligation set out in this clause 9.5 shall not apply in respect of any settlement made by Digimarc
without the consent of the BIS. 

  

	9.6	If the BIS Technology or any part thereof is held to infringe, or if the BIS believes that it is likely to be held to infringe, any of the Intellectual Property Rights
described in clause 9.4, the BIS may, in addition to its other obligations set out above, at its own expense either: 

  

	 	(a)	procure for Digimarc the right to continue using the allegedly infringing materials; or 

 

	 	(b)	replace or modify the materials to the reasonable satisfaction of Digimarc so that the materials are no longer infringing but remain functionally equivalent.

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	25	 	Confidential

	9.7	Digimarc hereby undertakes to assume and be responsible for the provision of intellectual property (IP) infringement indemnification in respect of any infringement or
alleged infringement of any third party IP rights of any kind (“IP Indemnification”) arising in respect of [**] that Digimarc [**] after 10 January [**] (“[**]”). [**]: (a) Digimarc has the right to direct the defense
of any infringement and indemnity claim; (b) the [**] shall take such actions as are reasonably requested by Digimarc in connection with managing, defending, and settling any claim or demand, including mitigation of damages; (c) to
facilitate mitigation or avoid infringement, Digimarc can supply, at its own cost, to the [**] with the CBCDG Contract Authority’s prior approval which shall not be unreasonably withheld; and (d) if the [**] the CBCDG Contract Authority
[**] as of the date of the notice. 

  

	9.8	Unless otherwise agreed between Digimarc and the CBCDG Project Director, [**]. Digimarc and the CBCDG Project Director shall mutually agree on a [**], such agreement
not to be unreasonably withheld. 

  

	9.9	Subject to clause 9.12(c), the [**]. [**], Digimarc shall provide indemnification [**] in accordance with its obligations under this Agreement, [**] provided that the
IP Indemnification is not terminated or that the Agreement is not terminated or otherwise expires. 

  

	9.10	In addition to any other BIS [**] obligations in this Agreement and in consideration of Digimarc’s continuing compliance at all times with its obligations under
clauses 9.7-9.12, the CBCDG Contract Authority shall [**] Digimarc for the IP Indemnification an[**]. [**]. 

  

	9.11	[**] is not included under the provisions of clauses 9.7-9.12. 

  

	9.12		(a)	 The BIS has the option, at its sole discretion, to terminate the IP Indemnification obligations of Digimarc under clauses 9.7-9.12:

  

	 	(i)	at the end of a calendar year and discontinue the [**] under clause 9.10 as of the end of that same calendar year with written notice by 15 November of that same
calendar year; or 

  

	 	(ii)	immediately on written notice if this Agreement is terminated pursuant to clauses 15.2, 15.3 or 15.5. 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	26	 	Confidential

	 	(b)	Digimarc has the option to terminate the indemnification obligations of Digimarc under clauses 9.7-9.12 if [**] under clause 9.10 and [**] is not made within thirty
(30) days of receipt of an IP Indemnification termination notice from Digimarc. 

  

	 	(c)	Upon termination of this IP Indemnification under clauses 9.12(a) or 9.12(b) or termination of the Agreement for any reason, Digimarc shall [**] from and the CBCDG
Contract Authority shall arrange for [**] except that if a [**] before such termination and Digimarc [**] within thirty (30) days of such termination, Digimarc shall [**], in accordance with clauses 9.7-9.12, [**]. 

 

	10.	REPRESENTATIONS AND WARRANTIES OF DIGIMARC 

  

	10.1	Digimarc represents, warrants and undertakes to the BIS that from and after the Effective Date: 

 

	 	(a)	the Services shall be of professional quality conforming to generally accepted [**] practices and shall be performed at all times in a timely and cost effective manner
and, for greater certainty Digimarc shall employ the standard of care in performing the work that would be expected of an [**] of the same or similar type as the [**] which comprises the CDS Technology and in the case of other Services, in a manner
that would be expected of a competent and experienced provider of the same or similar type of Services; 

  

	 	(b)	Digimarc shall ensure that its personnel are appropriately qualified, skilled, trained and experienced to undertake the Services and tasks assigned to them, and that
each of its personnel shall possess the qualifications and experience which Digimarc has represented them to possess; 

  

	 	(c)	Digimarc is duly incorporated and organized and is validly subsisting under the laws of the State of Oregon, U.S.A. or some other state in the United States with full
corporate power and authority to enter into this Agreement; 

  

	 	(d)	to the best of its knowledge, neither this Agreement nor the Services will contravene, breach, or result in any default under any agreement, permit, by-law, or law or
regulation to which Digimarc is subject or by which it is bound including, for greater certainty, any laws or regulations in effect in the United States governing export; 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	27	 	Confidential

	 	(e)	this Agreement when executed and delivered by Digimarc shall constitute a valid and binding agreement with Digimarc enforceable against Digimarc according to its terms;

  

	 	(f)	Digimarc owns all rights in and to, or is properly licensed in respect of, the Digimarc Technology and the Project Technology; 

 

	 	(g)	Digimarc shall at all material times have the right to grant the licenses to the Digimarc Technology, the Project Technology and the Improvements thereon as required by
this Agreement; and 

  

	 	(h)	for greater certainty, with the exception of the [**], neither the Project Technology, the Digimarc Technology or Improvements thereon infringe any Intellectual
Property Right of any Person. 

  

	10.2	Digimarc represents, warrants and undertakes to the BIS that: 

  

	 	(a)	incorporated as part of its [**] practices and procedures are those measures and security procedures commercially and reasonably available on the date for delivery of a
component of the CDS [**] in the CDS that could interfere with the use of the CDS or corrupt, interfere with or damage any data; 

  

	 	(b)	the CDS shall contain no lock, clock, timer, counter, copy protection feature, replication device or intentional defects (including “viruses” or
“worms” as such terms are commonly used in the computer industry), CPU serial number reference, or other device which might: 

  

	 	(i)	lock, disable or erase the CDS or any data which is loaded on the CDS so as to prevent full use of the CDS by authorized Persons; or 

	 	(ii)	require action or intervention by Digimarc or any other Person to allow properly trained and authorized Persons to use the CDS; 

 

	 	(c)	 the source code for the CDS, including that deposited with the Escrow Agent, shall, without reference to Digimarc or any of its employees or authorized
subcontractors, be understandable and usable by expert personnel familiar with the programming languages, and scientific and processing techniques, used therein, and shall not involve any programming components that such personnel could not
reasonably be expected to understand, and if necessary such source 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	28	 	Confidential

	 	 
code shall contain sufficient commentary to enable such personnel to understand and use such components; and 

 

	 	(d)	the Escrowed Materials deposited with the Escrow Agent under this Agreement shall contain all information in human readable form and on suitable media to enable an
expert technical consultant, familiar with the scientific and processing techniques used therein, to understand and use the same without reference to Digimarc or any of its employees and authorised subcontractors. 

 

	10.3	Digimarc represents, warrants and undertakes to the BIS that: 

  

	 	(a)	[**] accepted by the CBCDG Contract Authority shall meet the Specifications for that version from the date that it is accepted by the CBCDG Contract Authority until the
earlier of the date on which the next version is accepted by the CBCDG Contract Authority and the last day of the Term; and 

  

	 	(b)	until the last day of the Term, every [**] provided by Digimarc to any Person for incorporation into any Device shall be capable of meeting the performance criteria
which formed part of the Specifications for the version of the [**] last accepted by the CBCDG under this Agreement at the time such detector was so provided. 

 

	10.4	[**] shall not be counted in the determination under clause 10.3 as to whether or not an [**] meets the Specifications. 

 

	11.	REPRESENTATIONS AND WARRANTIES OF THE BIS 

  

	11.1	The BIS represents and warrants to Digimarc that: 

  

	 	(a)	the BIS has full power and authority to enter into this Agreement; 

  

	 	(b)	this Agreement when executed and delivered by the BIS shall constitute a valid, binding and enforceable obligation of the BIS; and 

 

	 	(c)	the BIS will at all material times have the right to grant the licenses required by this Agreement to the BIS Technology. 

 

	12.	CONFIDENTIALITY 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	29	 	Confidential

	12.1	Except as otherwise expressly permitted by this Agreement, a Recipient shall not use, reproduce or disclose the Confidential Information of the Discloser for any
purpose other than as reasonably necessary to comply with its obligations under this Agreement or to exercise any rights or licenses granted to it under or pursuant to this Agreement. 

 

	12.2	The Recipient shall protect the Confidential Information of the Discloser from disclosure by using the same degree of care, which shall be no less than a reasonable
degree of care, as the Recipient uses to protect its own confidential information. 

  

	12.3	On written request from the Discloser, the Recipient shall return, or certify the destruction of, all originals and copies of the Discloser’s Confidential
Information in the Recipient’s possession or control which the Recipient does not need to retain in order to perform any obligations imposed, or exercise any rights acquired, by this Agreement. 

 

	12.4	A Recipient may, on a need to know basis, and only for the purposes described in clause 12.1, give the Discloser’s Confidential Information to the Recipient’s
employees, authorized subcontractors or representatives provided that such employee, subcontractor or representative shall have entered into a non-disclosure agreement in respect of such Confidential Information in favor of the Discloser on terms
requiring at least five years of confidentiality from the date of disclosure of such Confidential Information but that are in all other respects materially similar to the provisions of this clause 12. For greater certainty, the BIS’
representatives shall include the CBCDG Contract Authority, the CBCDG Project Director and all representatives of members of the CBCDG. 

  

	12.5	The obligations set out in this clause 12 shall not apply to any Confidential Information that: 

 

	 	(a)	is or becomes publicly available other than through the fault of the Recipient; 

 

	 	(b)	was known to the Recipient prior to disclosure as shown by documentation sufficient to establish such knowledge; 

 

	 	(c)	was or is lawfully disclosed to the Recipient by a third party who did not breach any obligation of confidence by such disclosure and who made the disclosure without
restriction on further disclosure all of which is shown by documentation sufficient to establish the same; or 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	30	 	Confidential

	 	(d)	is required by law to be disclosed provided, however, that the Recipient shall first give written notice to the Discloser before the disclosure so that the Discloser
may seek an appropriate protective order. 

 The fact that Confidential Information, or any part thereof, can be
linked together by a search of publications and other information, followed by a selection of a series of such items of knowledge from unconnected sources, and fitting together those items of knowledge so as to duplicate or recreate any item of
Confidential Information, shall not be deemed to cause the Confidential Information, or any part thereof, to be included within exceptions (a), (b) or (c), above. 
  

	12.6	If either party is required by applicable law or regulation, by legal process or by the U.S. Securities and Exchange Commission or listing requirements of any exchange
or quotation system on which securities of any party may be listed or quoted, to disclose the terms of this Agreement (such disclosure being referred to herein as “Legally Required Disclosure”), such party shall provide the other party
with prompt notice of such requirement so that the other party may seek an appropriate protective order or remedy. In the event the other party fails to obtain an order or remedy that would permit the requested party not to disclose the required
terms, the disclosure shall be permitted, but the disclosing party shall use all reasonable efforts to have the disclosure treated confidentially by the recipient. 

 

	12.7	Nothing in this Agreement shall be construed to require the BIS or any representative of the BIS including, for greater certainty, the CBCDG Project Director or the
CBCDG Contract Authority, to disclose any information which is confidential to a third party including for greater certainty a [**]. 

  

	12.8	The BIS shall not reverse-engineer, disassemble, or decompile any [**] forming part of the CDS, including the [**] (except to the extent that (i) any such activity
is reasonably necessary to permit the BIS to exercise its [**] clause 8.2 of this Agreement or (ii) the BIS’ right to do so may not be contractually restricted under applicable law), and shall contractually assure that any other Person to
whom the BIS provides [**] shall be similarly obliged. 

  

	12.9	For greater certainty the obligations imposed by this clause 12 shall apply to the Escrowed Material. 

 

	12.10	 General attributes of the CDS may be disclosed in connection with promotion of the CDS to the [**] and [**], and to customers or prospects in related
markets; information 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	31	 	Confidential

	 	 
relating to the CDS Technology may be disclosed to [**], [**] subject to a nondisclosure agreement on terms requiring at least [**] years of confidentiality from the date of disclosure of such
Confidential Information, but that are in all other respects materially similar to the provisions of this clause 12, but in all such cases Digimarc may disclose information relating to the [**] only to [**] but to no others. The existence and terms
of this Agreement may be disclosed to the parties’ professional advisors, to members of the CBCDG, and to Digimarc’s shareholders, institutional and corporate investors, and commercial and investment bankers, who have a reasonable need to
know such information subject to a non-disclosure agreement, or as required by applicable law or regulations. 

  

	13.	AUDIT AND INSPECTION 

  

	13.1	The CBCDG Contract Authority, or its duly authorised representatives, may from time to time, without notice, at its own expense, conduct an audit or inspection during
normal business hours to verify Digimarc’s compliance with its obligations under this Agreement. Digimarc shall facilitate such audit activities by providing access to its premises, as well as any books, records, and other information relating
to this Agreement and the Services as may be reasonably requested by the CBCDG Contract Authority. The CBCDG Contract Authority shall promptly advise Digimarc in writing of the results of any audit. If the CBCDG Contract Authority exercises this
right more frequently than twice in each calendar year, the CBCDG Contract Authority shall reimburse Digimarc’s reasonable costs related thereto which costs are in addition to the Allowable Costs otherwise contemplated by this Agreement except
in the case where the exercise of such right is reasonably required to follow-up on a non-compliance detected during a previous audit or inspection. 

  

	13.2	If, as a result of any such audit, the CBCDG Contract Authority is of the view that Digimarc has engaged in or is about to engage in any act, or has omitted to perform
any act, which act or omission is not in compliance with Digimarc’s obligations under this Agreement, the CBCDG Contract Authority may issue to Digimarc a directive requiring Digimarc to refrain from engaging in such act or to perform such act
or acts as the CBCDG Contract Authority deems necessary, acting reasonably, for Digimarc to comply with this Agreement and Digimarc shall promptly comply with such directive at its own expense. 

 

	13.3	 No act performed by the CBCDG Contract Authority or its duly authorised representatives pursuant to the provisions of this clause 13 and no omission by
any of 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	32	 	Confidential

	 	 
them to perform an act pursuant to the provisions of this clause 13 shall in any way affect Digimarc’s obligation to comply with this Agreement. 

 

	14.	DISPUTE RESOLUTION 

  

	14.1	Any Dispute, as defined in the Arbitration Agreement, shall be finally settled by arbitration in accordance with the Arbitration Agreement. 

 

	14.2	Unless otherwise agreed between the parties or unless the subject matter of the dispute resolution proceedings is a party’s right to terminate this Agreement, the
Services shall continue during the arbitration proceedings and payments due to Digimarc shall not be withheld on account of such proceedings unless that particular Service or payment is the subject matter of the proceedings. Notwithstanding the
foregoing, the CBCDG Contract Authority may at its sole discretion instruct Digimarc to continue the performance of that Service, and Digimarc shall act in accordance with those instructions, subject to payment in accordance with this Agreement.

  

	15.	TERM AND TERMINATION 

  

	15.1	This Agreement shall take effect on the Effective Date and shall remain in force throughout the Term unless sooner terminated as provided herein. This Agreement may be
extended for five additional years upon mutual agreement. 

  

	15.2	The BIS may in its sole discretion terminate this Agreement effective immediately on notice to Digimarc if: 

 

	 	(a)	Digimarc makes a general assignment or any other arrangement for the benefit of its creditors; 

 

	 	(b)	a proposal or arrangement under applicable bankruptcy or insolvency legislation, or a petition is filed by or against Digimarc under applicable bankruptcy or insolvency
legislation and is not discontinued within thirty (30) days; 

  

	 	(c)	Digimarc is declared or adjudicated bankrupt or goes into liquidation; 

  

	 	(d)	a liquidator, trustee in bankruptcy, custodian, receiver, administrator, administrative - receiver, manager, or any other officer with similar power is appointed over
all or any part of the assets and undertaking of Digimarc; 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	33	 	Confidential

	 	(e)	Digimarc commits an act of bankruptcy, institutes proceedings to be adjudged bankrupt or insolvent, consents to the initiation of such appointment or proceedings or
admits in writing inability to pay debts generally as they become due; 

  

	 	(f)	Digimarc assigns this Agreement without the BIS` consent in breach of clause 18.7; or 

 

	 	(g)	Digimarc ceases or threatens to cease business. 

  

	15.3	Either party may terminate this Agreement effective immediately on notice to the other party if: 

 

	 	(a)	the other party fails, or is unable or refuses to perform any of its obligations under this Agreement (hereinafter referred to as a “Breach”) and fails to
remedy such Breach within sixty (60) days after receiving written notice of such Breach from the other party; or 

  

	 	(b)	an event of force majeure (as defined in clause 16) has continued for a period longer than sixty (60) continuous days or such longer period as the parties may
agree and no satisfactory alternative arrangements have been agreed to continue the Services. 

  

	15.4	Notwithstanding the foregoing, the BIS has no right to terminate this Agreement for Breach under clause 15.3 if the Breach consists of a failure by Digimarc to perform
a particular task the performance of which proves to be technically infeasible provided that the CBCDG Project Director has agreed with the Digimarc Project Director in writing before the task is commenced that the task may be technically
infeasible. 

  

	15.5	The BIS may terminate the Agreement for convenience without cause. Such termination shall be effective no earlier than six months from the date on which the BIS gives
written notice of such termination to Digimarc. 

  

	15.6	In the event of a termination for convenience under this clause 15, Digimarc shall be paid all of its actual and reasonable termination costs including:

  

	 	(a)	third party contract termination costs; 

	 	(b)	employee re-deployment or termination costs including severance, outplacement, benefits, acceleration of stock compensation and employer paid payroll taxes;

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	34	 	Confidential

	 	(c)	stay bonuses approved by the CBCDG Contract Authority to retain key employees through contract termination date; 

	 	(d)	undepreciated capital costs of assets purchased exclusively for the project, plus [**]; and 

	 	(e)	accounting, legal and travel costs associated with termination and termination negotiations (all collectively “Termination Costs”). 

Digimarc shall use commercially reasonable efforts to mitigate all Termination Costs. 

 

	 	15.7	Actual and reasonable Termination Costs shall be capped [**]. 

  

	15.8	Under a termination for convenience under clause 15, Digimarc shall also be paid an amount equal to [**]. 

 

	15.9	If an approved Plan Budget for any calendar year does not amount to at least [**], Digimarc has the option to consider this a termination for convenience. If Digimarc
exercises this option, Digimarc shall be paid the amounts in clauses 15.6-15.8. Within [**] months of the approval of a Plan Budget below [**], Digimarc can exercise the option with notice. If Digimarc exercises this option, the agreement will
terminate [**] months after notice from Digimarc. 

  

	15.10	On termination of this Agreement for any reason, the TAP shall be implemented and Digimarc shall be reimbursed for all Services performed through the date of
termination and for any transition services provided under the TAP. 

  

	15.11	On termination of this Agreement for any reason, the [**] by Digimarc under clauses 2.2, 2.3 and 2.8 shall continue, but the CBCDG Contract Authority shall make
arrangements to assume all of: (a) Digimarc’s obligations of support and other Digimarc resource allocation; and (b) Digimarc’s obligations arising from or related to any third party threat or claim for IP infringement brought
against any such licensees, subject to clause 9.12(c). 

  

	15.12	On termination of this Agreement for any reason, Digimarc shall within fifteen (15) Business Days deliver to the Escrow Agent all work in progress done up to the
effective date of termination which has not previously been deposited with the Escrow Agent and issue to the CBCDG Contract Authority a certificate signed by an authorized representative of Digimarc that it has fully complied with this obligation.
Digimarc shall be entitled to charge for its reasonable costs in providing such assistance calculated in accordance with the Allowable Costs. 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	35	 	Confidential

	16.	FORCE MAJEURE 

  

	16.1	If the performance by any of the BIS, Digimarc, the CBCDG, the CBCDG Contract Authority, the CBCDG Project Director or the CBCDG Project Office (the “Obstructed
Party) of any of its obligations under this Agreement is prevented or delayed by any circumstance of force majeure, which shall mean fire, flood, earthquakes, war, riots, or insurrection, the Obstructed Party shall immediately provide notice under
clause 17. 

  

	16.2	The time period within which the Obstructed Party is obliged to perform its obligations shall be delayed during the period such circumstance exists. During the period
of delay the Obstructed Party shall use commercially reasonable efforts to make alternate arrangements satisfactory to the other Persons mentioned in clause 16.1 to avoid delay or resume performance. 

 

	17.	NOTICES 

  

	17.1	All notices under this Agreement shall be delivered by fax, or recognized international courier service. The notice shall be deemed effective as of the date of delivery
to the address of the party specified below as evidenced by a delivery receipt or the addressee’s registry of incoming correspondence. Unless otherwise expressly set out in this Agreement, all notices to a party shall be sent to the
party’s authorized representative identified below and all notices from a party shall be sent by the party’s authorized representative identified below. 

 

	17.2	Any notice to Digimarc shall be sent to, and any notice from Digimarc shall be sent by: 

Mr. Robert Chamness 
 Executive Vice President and 
 Chief Legal Officer and Secretary 

Digimarc Corporation 
 9405 SW Gemini Drive 
 Beaverton, Oregon 97008 USA 

FAX:   (503) 469-4777 
 With a copy to:    Mr. George Rieck 
 Vice President,
Government Programs and 
 Digimarc Project Director 
 Digimarc Corporation 
 9405 SW Gemini Drive 

Beaverton, Oregon 97008 USA 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	36	 	Confidential

 FAX:   (503) 469-4777 

 

	17.3	Any notice to the BIS shall be sent to, and any notice from the BIS shall be sent by: 

Bank for International Settlements 
 [**] 
 Centralbahnplatz 2 

CH-4002 Basel, Switzerland 
 [**] 
 With a copy to:     [**] 

Any notice to the CBCDG shall be sent to, and any notice from the CBCDG shall be sent by: 

[**] 
 With a
copy to:    Bank for International Settlements 
 [**] 

Centralbahnplatz 2 
 CH-4002 Basel, Switzerland 
 [**] 

 

	17.4	A party may change its addressee(s) or address(es) for notice by notice to the other party in accordance with the provisions of this clause 17.

  

	18.	MISCELLANEOUS PROVISIONS 

  

	18.1	Remedies Cumulative - Except as otherwise expressly set out in this Agreement: 

 

	 	(a)	each and every right, power and remedy of a party shall be considered to be cumulative with and in addition to any other right, power and remedy which such party may
have at law or in equity in the event of breach of any of the terms of this Agreement; 

  

	 	(b)	the exercise or partial exercise of any right, power or remedy shall neither constitute the exclusive election thereof nor the waiver of any other right, power or
remedy available to such party; and 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	37	 	Confidential

	 	(c)	a party terminating this Agreement in accordance with the provisions of this Agreement shall have no liability or obligation to the other as a result of or with respect
to the termination. 

  

	18.2	Severability.   If any part of this Agreement is held by an arbitral tribunal appointed pursuant to the Arbitration Agreement or by any other competent
authority to be void or unenforceable, the parties agree that such determination shall not result in the nullity or unenforceability of the remaining parts of this Agreement, which shall continue in force to the fullest extent permitted by law. The
parties further agree to replace such void or unenforceable part of this Agreement with a valid and enforceable provision that will achieve, to the extent legally permissible, the economic, business and other purposes of the void or unenforceable
part. 

  

	18.3	Counterparts.   This Agreement may be executed in separate counterparts, and by facsimile, each of which shall be deemed an original, and when
executed, separately or together, will constitute a single original instrument, effective in the same manner as if the parties had executed one and the same instrument. 

 

	18.4	Entire Agreement.   This Agreement is intended by the parties to be the final expression of their agreement and constitutes and embodies the entire
agreement and understanding between the parties hereto and constitutes a complete and exclusive statement of the terms and conditions thereof, and shall supersede any and all prior correspondence, conversations, negotiations, agreements or
understandings between the parties relating to the same subject matter from the Effective Date. Nothing in this clause 18.4 shall operate so as to limit or exclude any liability for fraud or fraudulent misrepresentation.

  

	18.5	Amendments.   No change in, modification of or addition to the terms and conditions contained herein shall be valid as between the parties unless set
forth in a writing that is signed by an authorized representative of each party and which specifically states that it constitutes an amendment to this Agreement. 

 

	18.6	Waiver.   No waiver of any term, provision, or condition of this Agreement shall be effective unless in a written document signed by the waiving party
and no such waiver in any one or more instances, will be deemed to be, or be construed as, a further or continuing waiver of that term, provision or condition or any other term, provision or condition of this Agreement. 

 

	18.7	 Assignment and Successors.   This Agreement may not be assigned, novated or otherwise transferred by Digimarc without the prior
written consent of the BIS, which consent shall 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	38	 	Confidential

	 	 
not be unreasonably withheld. For the purpose of this Agreement, an assignment includes a change in the voting control of Digimarc or the sale or other disposal of substantially all of
Digimarc’s assets. This Agreement and all of its terms, conditions and covenants are intended to be fully effective and binding, to the extent permitted by law, on the successors and permitted assigns of the parties hereto.

  

	18.8	Captions.   Captions are provided in this Agreement for convenience only and they form no part, and are not to serve as a basis for interpretation or
construction, of this Agreement, nor as evidence of the intention of the parties. 

  

	18.9	Disclaimer of Agency.   Nothing contained in this Agreement is intended or shall be interpreted so as to constitute the parties to this Agreement as
partners or joint venturers or as agents of each other. Neither party shall have any express or implied right or authority to assume or create any obligations on behalf of or in the name of any other party or to bind any other party in any contract,
agreement or undertaking with any third party. No employee of a party shall be deemed or considered to be an employee of the other party or of both parties. 

 

	18.10	The parties agree that from time-to-time it will be beneficial to both parties to issue press releases and other public announcements concerning benefits arising from
the [**] of the CDS. Each party agrees to submit such releases or announcements for prior approval by the other party if the name of the other party is mentioned, which approval may be withheld by the other party in its sole discretion. Any Digimarc
press releases and public announcements that mention the CDS or the CBCDG must be pre-approved by the CBCDG Project Director. 

  

	18.11	Effectiveness.   This Agreement shall be effective only after it is signed by both of the parties. 

 

	18.12	Ambiguities.   Each party and its counsel have participated fully in the review and revision of this Agreement. Any rule or construction to the effect
that ambiguities are to be resolved against the drafting party shall not apply in interpreting this Agreement. 

  

	18.13	Survival.   All clauses of this Agreement which expressly or by implication are intended to survive the termination of this Agreement shall do so and,
for greater certainty and notwithstanding any provision in this Agreement to the contrary, the provisions set out in clauses 1.3, 2.14, 6.1-6.8, 8, 9.1-9.6, 9.10, 9.12(c) and 10-18 of this Agreement shall survive termination of this Agreement by
either party for any reason. 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	39	 	Confidential

	18.14	No third party Person shall have any right to enforce any provision of this Agreement under the Contracts (Rights of Third Parties) Act 1999. 

 
  
 IN WITNESS
WHEREOF, this Agreement has been executed and delivered by the parties hereto as of the Effective Date. 
  

 

					
	BANK FOR INTERNATIONAL SETTLEMENTS	  		  	DIGIMARC CORPORATION
			
	/s/
[**]                                        
	  		  	/s/ Robert
Chamness                                  
	Signature	  		  	Signature
			
	Name: [**]	  		  	Name: Robert Chamness
			
	Title:   [**]	  		  	 Title: Executive Vice President, Chief Legal
 Officer and Secretary

			
	Date:     6 December 2012	  		  	 Date:   December 6, 2012

  

	
	/s/
[**]                                         
         
	Signature
	
	Name: [**]
	
	Title: [**]
	
	Date:   6 December 2012

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
			
	CDS DLA 1-January 2013	 	40	 	Confidential

 SCHEDULE A 
 SYSTEM DESCRIPTION 
  

	1.0	GENERAL DESCRIPTION OF THE COUNTERFEIT DETERRENCE SYSTEM (“CDS”) 

 The CDS is a system for the deterrence of the unauthorized digital reproduction of bank notes by the use of personal computer-based equipment. [**] 

The capitalized terms in this Schedule A have the meanings provided in the Renewed and Extended Counterfeit Deterrence System Development and License
Agreement and are not elaborated herein. 
  

	2.0	FUNCTIONAL DESCRIPTION OF THE CDS 

 The
CDS is comprised of the following three subsystems: 
  

	 	1.	[**] 

  

	 	2.	[**] 

  

	 	3.	[**] 

 The functions of the various subsystems
and components described below may be changed by the [**]. 
  

	2.1	[**] 

  

	  2.1.1	  [**] 

  

	  1.	  [**] 

  

	  2.	  [**] 

  

	  3.	  [**] 

  

	  4.	  [**] 

  

	  2.1.2	  [**] 

  

	  1.	  [**] 

  

	  2.	  [**] 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule A: System Description - 1 January 2013	 	1

	  3.	[**] 

  

	2.2	[**] 

  

	  1.	[**] 

  

	  2.	[**] 

  

	  3.	[**] 

  

	  4.	[**] 

  

	 	(a)	[**] 

	 	(b)	[**] 

	 	(c)	[**] 

  

	  5.	[**] 

  

	  6.	[**] 

  

	  7.	[**] 

  

	  8.	[**] 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule A: System Description - 1 January 2013	 	2

 SCHEDULE B 
 DIGIMARC TECHNOLOGY 
 The Digimarc Technology includes techniques and system applications
for [**]. 
 This technology is partially described in the following issued representative U.S. and International patents: 

 

			
		  	US 5,768,426
	US 5,636,292 C1	  	US 5,809,160
	US 5,710,834	  	US 5,832,119 C1
	US 5,721,788	  	US 5,850,481 C1
	US 5,745,604	  	[**]
	US 5,748,763	  	

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule B: Digimarc Technology - 1 January 2013	 	1

 SCHEDULE C 
 PROJECT TECHNOLOGY 
 The Project Technology includes: 

 

	1.	The modification of techniques for using the Digimarc Technology and the BIS Technology in the [**]. 

 

	2.	The effects and behaviors of [**] when used in [**]. 

  

	3.	The effects of various types [**]. 

  

	4.	Improvements to Digimarc’s testing and certification processes used in testing and certifying [**]. 

 

	5.	The improvement of [**]. 

  

	6.	The use of [**]. 

  

	7.	Examples of Project Technology include: 

  

 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule C: Project Technology - 1 January 2013	 	1

 

 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule C: Project Technology - 1 January 2013	 	2

 

 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule C: Project Technology - 1 January 2013	 	3

 [**] 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule C: Project Technology - 1 January 2013	 	4

 SCHEDULE D 
 SECURITY REQUIREMENTS 
  

	1.	Digimarc shall implement the security measures normally followed by a [**] and distributor comparable to Digimarc in number of employees and revenue engaged in the
development and distribution of [**] and maintain such security measures in effect at all times throughout the Term. The security measures will include: 

  

	 	1.1.	Electronic security for protection of the network and protection of the CDS [**] products that are under development. 

 

	 	(a)	Network protection which will ensure that unauthorized users will not get access to [**]. This protection will include: 

 

	 	    i.	erecting barriers to prevent hackers, whether inside or outside the Digimarc facility, from accessing the secure network; and 

 

	 	    ii.	the customizing of developmental and operational procedures for the software development team that maximizes security while not impeding the team’s ability to work
efficiently and effectively. 

  

	 	1.2	        Physical security, including the following: 

 

	 	(a)	the Digimarc facility at which the Services will be performed will be secure from unauthorized visitors; 

 

	 	(b)	the development laboratory and the computer network employed in the Services shall be secure; 

 

	 	(c)	all personnel authorized to have access to sensitive CDS information, data and designs including the employees of authorized subcontractors will be properly screened;
and 

  

	 	(d)	production and handling of interim and final versions of the Deliverables will be carefully controlled, monitored and audited. 

 

	2.	[**] 

  

	3.	The CBCDG can conduct an audit, at its own expense, of the security measures with ten (10) Business Days’ notice. 

 

	4.	Following any such audit, the CBCDG Project Director shall submit an audit report to Digimarc which will prescribe the actions which Digimarc must take, if any, to
improve the security measures to be followed by Digimarc to make such measures consistent with item 1 of this Schedule D and the dates by which Digimarc shall take them. 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule D: Security Requirements - 1 January 2013	 	1

 SCHEDULE E TRAINING 

 

	1.0	As part of the Services, Digimarc shall develop a program of training acceptable to the CBCDG Project Director in the [**]. 

 

	2.0	Digimarc shall deliver Training as follows: 

  

	 	2.1	Digimarc shall provide the Training for multiple people simultaneously. The exact number of trainees is to be agreed upon by both parties prior to Training. The
trainees will be experienced in digital design operation. 

  

	 	2.2	Digimarc shall conduct the Training at the facilities of the [**] or at the request of the [**] at Digimarc’s facilities or at some other place agreed between
Digimarc and the [**]. 

  

	 	2.3	Digimarc shall give the [**] reasonable notice concerning the equipment which Digimarc will require in order to conduct the Training. The [**] shall provide all such
equipment at its own expense. If the parties are unable to agree on the equipment to be provided either party may refer the matter for decision to the CBCDG Contract Authority. 

 

	 	2.4	Digimarc shall conduct the Training using a [**] or other training designs as provided by Digimarc. 

 

	 	2.5	Digimarc shall provide a training manual in English to every trainee. Any translation or interpretation which the trainees may require will be provided by the [**] at
its own expense. 

  

	 	2.6	Digimarc shall conduct the training in English. Any translation or interpretation which the trainees may require will be provided by the [**] at its own expense.

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule E: Training - 1 January 2013	 	1

 SCHEDULE F 
 ALLOWABLE COSTS 
  
  

	1.	For the purposes of this Schedule F: 

 [**] 
 [**] 

[**] 
 [**]

 [**] 
  

			
	 [**]
	  	
[**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	[**]	  	
	 [**]
	  	
[**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	
[**]

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule F: Allowable Costs - 1 January 2013	 	1

			
	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	 [**]
	  	 [**]

	[**]	  	
		  	
	 [**]
	  	
		  	
	[**]	  	

			
	[**]                    
	  	[**]
	[**]	  	
1.        [**]

	[**]	  	[**]
	[**]	  	[**]
	[**]	  	[**]
	[**]	  	[**]
	[**]	  	
1.        [**]

	[**]	  	[**]
	[**]	  	[**]
	[**]	  	
1.        [**]

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule F: Allowable Costs - 1 January 2013	 	2

 SCHEDULE G 
 ARBITRATION AGREEMENT 
 This is an Agreement by and among the Parties to
the Agreements listed in Schedule A to submit for final and binding resolution by international arbitration all Disputes (as defined below) arising out of or otherwise connected to a project relating to the development and potential licensing,
marketing and servicing of a Counterfeit Deterrence System (as defined in the Renewed and Extended Development and License Agreement identified below) and the services of Digimarc (as defined below) in relation to the project. 

WHEREAS, Digimarc Corporation, a corporation existing under the laws of the State of Oregon, USA, has developed and is developing, in
conjunction with a group of central banks known as the Central Bank Counterfeit Deterrence Group (the “CBCDG”) technology [**] (the “Counterfeit Deterrence System” or “CDS” as defined in the Development and License
Agreement identified below); 
 WHEREAS, the CBCDG has asked the Bank for International Settlements, an international
organisation created as a result of the Hague Agreements of January 1930 (the “BIS”), to provide it with limited assistance in connection with the development and potential subsequent licensing of the CDS as set out in a Renewed and
Extended Development and License Agreement (the “DLA”) effective from 1 January 2013; 
 WHEREAS, in the course
of performance of the DLA, Digimarc may be directed to issue licenses to certain [**] in accordance with standard forms of license agreement which are approved by the CBCDG; 
 WHEREAS, [**], pursuant to an [**], as amended from time to time, (the “[**]”), agreed to compensate and to indemnify and hold harmless the [**] in respect of any liability in connection with
the project; 
 WHEREAS, given the international nature of the Agreements (as defined below), all the Parties (as defined below)
to the Agreements are desirous to avoid recourse to national courts and the potential expense and delay of prosecuting connected Claims (as defined below) in more than one proceeding and also to exclude the risk of having to apply contradictory or
inconsistent fact-findings, conclusions, judgments or awards for any Dispute (as defined below) which may arise between or among the Arbitrating Parties (as defined below) and instead wish to resort to international arbitration as the exclusive
means of resolving in a final, binding and consistent manner all Disputes arising in 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule G: Arbitration Agreement - 1 January 2013	 	1

 
connection with the Agreements for the CDS and of establishing through this Arbitration Agreement a mechanism to these ends. 

The Parties agree as follows: 
  

	1.	The meaning of the following terms in this Arbitration Agreement shall be as set out below: 

 

	 	a)	“Agreements” shall mean the agreements, contracts, schedules or other arrangements in connection with the development or licensing or marketing or servicing
of the CDS listed in Schedule A, as amended from time to time. 

  

	 	b)	“Appointing Authority” shall mean the [**]. 

  

	 	c)	“Arbitrating Party” or “Arbitrating Parties” shall mean (i) any and all Parties which have become involved in any arbitration under this
Arbitration Agreement as Claimants or Respondents or (ii) any and all Parties which have been otherwise joined to any arbitration under this Arbitration Agreement or (iii) the BIS, Digimarc, any [**] or any [**] in the aforementioned
circumstances or when it or they has or have exercised their right of Intervention in any arbitration under this Arbitration Agreement. 

  

	 	d)	“[**]” shall mean any [**] which is represented on the CBCDG from time to time. 

 

	 	e)	“CBCDG Project Office” shall mean the project office established by the CBCDG, or its staff as the case may be, and that is responsible for the oversight of
the overall relationship among the BIS, the [**] and Digimarc and for the key day to day project management. 

  

	 	f)	“Claim” shall include without limitation any claim or counterclaim or crossclaim made by an Arbitrating Party. 

 

	 	g)	“Claimant” or “Claimants” shall mean any Party which, either separately or together with any other Party or Parties, initiates arbitration under
this Arbitration Agreement. 

  

	 	h)	“Dispute” shall mean any dispute, difference, controversy or claim between or among the parties arising out of or relating to or in connection with this
Arbitration Agreement or any of the Agreements listed in Schedule A, including their signature, validity, interpretation, performance, amendment, breach, termination and post-termination obligations. 

 

	 	i)	 “Intervention” shall mean the right of any of the BIS, Digimarc, any [**] or any [**] under Articles 8(e)-(h) to intervene into a
particular arbitration as an Arbitrating Party even when it is not a Claimant or Respondent and has not been joined into any 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule G: Arbitration Agreement - 1 January 2013	 	2

	 	 
arbitration by an Arbitrating Party. 

  

	 	j)	“[**]” shall mean an entity responsible for the [**] that is licensed by Digimarc to use the CDS. 

 

	 	k)	“Notice of Arbitration” shall mean the document given when initiating recourse to arbitration or to join any Party as Arbitrating Party as well as to initiate
recourse in arbitration against any Party which is already an Arbitrating Party. 

  

	 	l)	“Party” or “Parties” shall mean any person, company or organization that is party to one of the Agreements listed in Schedule A and that has agreed
in writing to be bound by the terms of this Arbitration Agreement. 

  

	 	m)	“Respondent” or “Respondents” shall mean any Party which, either separately or together with any other Party, is named as a Respondent in
arbitration by any Claimant or Claimants. 

  

	 	n)	In interpreting this Arbitration Agreement, singular shall be read for plural where appropriate to reflect the multi-party nature of any arbitration.

  

	2.	Any Dispute shall be finally settled by arbitration under the [**] as in force at the date of commencement of this Arbitration Agreement except as the [**] Rules are
modified in the body and Schedule B of this Arbitration Agreement and to the exclusion of any provisions of the [**] Rules as are inconsistent with the express provisions of this Arbitration Agreement or with the multi-party nature of an arbitration
under this Arbitration Agreement. 

  

	3.	The language used in any arbitration shall be English. All documents submitted into any arbitration shall be in English or submitted with a complete English
translation. Oral evidence may be submitted in a language other than English provided that the Arbitrating Party submitting the oral evidence makes provision for its simultaneous interpretation into English. The cost of any translation or
interpretation into English shall be borne entirely by the Arbitrating Party on whose behalf the non-English document or oral evidence is submitted and shall not be included among the “costs of arbitration” apportioned pursuant to Article
40 of the [**] Rules. 

  

	4.	The place of Arbitration shall be [**]. 

  

	5.	Arbitration pursuant to this Arbitration Agreement shall be the sole and exclusive means for resolving any Dispute. 

 

	6.	No entity shall become a Party unless that entity has agreed in writing to be bound by the terms of this Arbitration Agreement. 

 

	7.	 Each Party to this Arbitration Agreement hereby expressly accepts the addition of new

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule G: Arbitration Agreement - 1 January 2013	 	3

	 	 
parties to this Agreement. 

  

	8.	

  

	 	a)	Any Claimant or Claimants shall initiate recourse to arbitration by giving to each Respondent a Notice of Arbitration and statement of claim which specify, inter
alia, the Agreement or Agreements involved in the Dispute. Any Claimant or Claimants shall also at the same time send a copy of the same Notice of Arbitration and statement of claim to all other Arbitrating Parties, the BIS, the CBCDG Project
Office and the [**]. Arbitration shall be deemed to commence upon receipt of the Notice of Arbitration and statement of claim by the [**]. 

  

	 	b)	Within thirty (30) days of the date on which each Respondent received the Notice of Arbitration, a Respondent may give a third party Notice of Arbitration in order
to join into the arbitration any Party or Parties as an Arbitrating Party or Arbitrating Parties. The Respondent shall also at the same time send a copy of any third party Notice of Arbitration to all other Arbitrating Parties, the BIS, the CBCDG
Project Office and the [**]. 

  

	 	c)	Any third party joined as an Arbitrating Party may, within thirty (30) days of receipt of any third party Notice of Arbitration, give fourth party Notices of
Arbitration in order to join any Party or Parties as an Arbitrating Party or Arbitrating Parties. The third party shall also at the same time send a copy of any fourth party Notice of Arbitration to all other Arbitrating Parties, the BIS, the CBCDG
Project Office and the [**]. 

  

	 	d)	Other Parties may be joined as further additional Arbitrating Parties by any Arbitrating Party or Arbitrating Parties until such time as thirty (30) days have
elapsed without a new Arbitrating Party being joined into the arbitration. 

  

	 	e)	The BIS, whether or not joined as a Respondent or as a further additional Arbitrating Party, shall have the right to intervene in any arbitration by giving a Notice of
Arbitration to each of the Arbitrating Parties within thirty (30) days after receipt of the copy of a Notice of Arbitration from the last Arbitrating Party to be joined or from the last Party to request permission to intervene under Article
8(f). The BIS shall also at the same time send a copy of the Notice of Arbitration to the CBCDG Project Office, the [**] and to all other Arbitrating Parties. 

 

	 	f)	Digimarc, any [**], whether or not joined as a Respondent or as a further additional Arbitrating Party, shall have the right to ask the arbitrator for permission to
intervene in any arbitration by giving a Notice of Arbitration to each of the Arbitrating Parties within thirty (30) days after receipt of the copy of a Notice of Arbitration from the last Arbitrating Party to be joined or from the BIS. The
Party requesting to intervene shall also at the same time send a copy of the Notice of Arbitration to the BIS, the CBCDG Project Office, the [**] and to all other Arbitrating Parties. 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule G: Arbitration Agreement - 1 January 2013	 	4

	 	g)	The CBCDG Project Office shall, upon receipt of any Notice of Arbitration under this Article 8 of this Arbitration Agreement, send a copy of such Notice of Arbitration
to all Parties. 

  

	 	h)	The arbitral tribunal, once constituted and after affording the Arbitrating Parties a reasonable period of time in which to comment, shall have the authority to require
by an order that any Party or Parties which is not or are not an Arbitrating Party or Arbitrating Parties (including Digimarc, any [**] requesting intervention under Article 8(f)) shall nonetheless be joined into the arbitration as an Arbitrating
Party or Arbitrating Parties should the arbitral tribunal determine that: (a) the absence of said Party or Parties from the pending arbitration would prevent the according of complete relief in regard to the Claims of the Arbitrating Parties;
or (b) that the Party or Parties has or have a real and significant interest in the Agreement or Agreements out of or in connection with which the Disputes involved in the pending arbitration have arisen and that the absence of said Party or
Parties would significantly impede its or their ability to protect that interest. Any such order issued by the arbitral tribunal shall be final and binding upon the Parties that are the subject of that order and such Parties will be considered
Arbitrating Parties to that Claim or Dispute. 

  

	 	i)	Any Arbitrating Party may join into a pending arbitration any Dispute which presents issues of law or fact common with those in the Dispute or Disputes already in the
pending arbitration by issuing, within 30 days of its receipt of a Notice of Arbitration, a Notice of Arbitration and a statement of claim which specify, inter alia, the Agreement or Agreements involved in the Dispute and set out the issues
of law or fact it alleges are common with those in the Dispute or those Disputes already in the pending arbitration. 

  

	 	j)	The arbitral tribunal shall determine by an order, which shall be final and binding upon the Arbitrating Parties, any issue raised by an Arbitrating Party as to whether
or not a Dispute joined into any pending arbitration did, in fact, at the time it was joined into the arbitration, present issues of law or fact common with those presented in other Disputes in the pending arbitration. Any Dispute which is found not
to have presented common issues of law or fact shall be dismissed without prejudice from the pending arbitration. 

  

	 	k)	Joinder of any Party or Parties or of any Dispute or Disputes to any arbitration pursuant to this Arbitration Agreement shall be permitted only when made in accordance
with the provisions of this Arbitration Agreement, including the strict time limits and no joinder or Intervention other than those provided for shall be permitted. 

 

	 	l)	Any multi-party arbitration arising as a result of there being more than two Arbitrating Parties will be conducted as a single arbitration involving all
Arbitrating Parties. 

  

	 	m)	 Any Arbitrating Party giving any Notice of Arbitration or sending any copy of a

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule G: Arbitration Agreement - 1 January 2013	 	5

	 	 
Notice of Arbitration shall send to each recipient according to the provisions set out above a full copy of the document by international courier or other appropriate means of ensuring rapid and
certain delivery and, when required to send documents to several recipients, the Arbitrating Party shall send all documents on the same day. 

  

	 	n)	Any advances deemed necessary to cover the costs of any arbitration shall be made in equal shares by all Arbitrating Parties, provided that multiple Claimants or
multiple Respondents shall be deemed to constitute one Arbitrating Party for purposes of this subparagraph only, and provided further that should any Arbitrating Party fail to advance its share (a “Defaulting Arbitrating Party”), it shall
be the responsibility of the Arbitrating Party which gave the Notice of Arbitration against the Defaulting Arbitrating Party or Defaulting Arbitrating Parties to advance the share due from the Defaulting Arbitrating Party or Defaulting Arbitrating
Parties. Any Claim brought by a Defaulting Arbitrating Party shall be dismissed without prejudice. However, the recipient of any Notice of Arbitration given by a Defaulting Arbitrating Party shall continue to be an Arbitrating Party if it has itself
given any Notice of Arbitration, unless it withdraws any such Notice of Arbitration. Should any Defaulting Arbitrating Party commence arbitration in order to reassert any Claim which has been dismissed pursuant to this subparagraph, that Claim shall
be consolidated with the pending arbitration from which it was dismissed and the Defaulting Arbitrating Party shall not be permitted to proceed with that Claim until it has advanced its share of the costs of the pending arbitration.

  

	9.	If any Dispute arises whilst an arbitration is pending in accordance with the provisions of this Arbitration Agreement, but one or more of the Arbitrating Parties to
that Dispute cannot be joined to the pending arbitration in accordance with the provisions of Article 8 of this Arbitration Agreement, the Dispute and the Arbitrating Parties thereto shall nonetheless be joined into the pending arbitration at the
request of a Party which is an Arbitrating Party in both the pending arbitration and the Dispute which has arisen so that the Disputes may be resolved in the same arbitration, provided the arbitral tribunal decides that the later Dispute presents
issues of law or fact common with those in the pending arbitration and that joinder under these circumstances would not result in undue delay for the pending arbitration. 

 

	10.	 Each Party agrees that neither an arbitral tribunal established pursuant to this Arbitration Agreement nor the Parties shall be authorised to take or
seek from any arbitral tribunal or judicial authority any interim measure or any pre-award relief against the BIS, any provision of the [**] Rules notwithstanding. Nothing in this Arbitration Agreement shall operate or be regarded as a waiver,
renunciation or other modification of the [**] BIS [**], of whatever nature and wherever situated, under international convention or under any applicable law. Except as otherwise provided in this Article 10 with regard to the BIS, each Party
irrevocably agrees that, to the extent that it or any of its assets has or hereafter may acquire any right of immunity, whether characterized as sovereign immunity or otherwise, from any legal proceedings, whether in [**] or elsewhere, to enforce or
collect upon any obligation of that Party in connection with the transaction contemplated under any Agreement, including, without limitation, immunity from 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule G: Arbitration Agreement - 1 January 2013	 	6

	 	 
jurisdiction of any arbitral tribunal, immunity from service of process, immunity from execution of judgment and immunity of any of its property from attachment prior to the rendering of an
arbitral award under this Arbitration Agreement or entry of judgment, it hereby expressly and irrevocably waives all such immunity. 

  

	11.	

  

	 	a)	Any Dispute, regardless of the number of Arbitrating Parties, shall be submitted to an arbitral tribunal of three (3) arbitrators appointed by the Appointing
Authority. 

  

	 	b)	The arbitral tribunal shall be appointed by the Appointing Authority once the time has terminated during which i) any Party is entitled to give a Notice of Arbitration
to join any other Party, ii) the BIS is entitled to intervene and (iii) Digimarc, any [**] is entitled to request permission to intervene. 

  

	 	c)	The presiding arbitrator of the arbitral tribunal shall be a British national and shall have been admitted to practice as a barrister or solicitor in England and shall
also have significant expertise in the resolution of disputes in international commercial matters. All arbitrators shall have a full command of the English language. 

 

	 	d)	The arbitrators appointed in accordance with this Arbitration Agreement shall be remunerated in accordance with the provisions of the rules of the [**] in effect at the
time any arbitration is commenced. 

  

	12.	Awards shall be final and binding as from the date the awards are made. The Arbitrating Parties undertake to carry out all awards without delay and waive their right to
any form of appeal or recourse to a court of law or other judicial authority, insofar as any such waiver may validly be made. All awards may, if necessary, be enforced by any court having jurisdiction in the same manner as the judgment of any such
court. 

  

	13.	Each Arbitrating Party explicitly agrees hereby that it shall recognise any arbitral award rendered in arbitration under this Arbitration Agreement as final and binding
upon it unless a competent arbitral tribunal or a competent judicial authority determines that said Arbitrating Party never received notice of the pendency of the arbitration in which the award was rendered. 

 

	14.	Any arbitral award rendered under this Arbitration Agreement shall be accorded res judicata effect by any arbitral tribunal appointed under this Arbitration
Agreement in regard to those Arbitrating Parties which are bound by an award pursuant to Article 13. 

  

	15.	The obligations of the Parties to the Agreements shall not be altered or suspended by reason of any arbitration being conducted during the life of any Agreement.

  

	16.	Any Agreement in regard to which a Dispute has arisen shall be governed by the applicable law as specified in that Agreement. 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule G: Arbitration Agreement - 1 January 2013	 	7

	17.	This Arbitration Agreement shall bind and inure to the benefit of the respective successors and permitted assigns of the Parties, subject to all Parties respecting
Articles 6 and 7 hereto. 

  

	18.	This Arbitration Agreement may be executed in several counterparts, each of which shall be deemed an original, but all of which together shall constitute one and the
same agreement. 

  

	19.	Any provision of this Arbitration Agreement which is invalid or unenforceable in any jurisdiction shall, as to such jurisdiction, be ineffective to the extent of such
invalidity or unenforceability, without invalidating the remaining provisions of this Agreement or affecting the validity or enforceability of such provision in any other jurisdiction. 

 

	20.	This Arbitration Agreement shall enter into full force and effect on 1 January 2013 or such later date on which a Party agrees in writing to be bound by the terms
of this Arbitration Agreement and shall continue in full force and effect indefinitely, unless it is terminated by mutual written consent of all of the Parties. 

 

	21.	This Arbitration Agreement shall be governed by and construed in all respects in accordance with the laws of England, to the exclusion of its rules of conflicts of law.

 The Parties have caused this Arbitration Agreement to be executed in multiple copies, with effect from
1 January 2013. 
 [Signatures] 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule G: Arbitration Agreement - 1 January 2013	 	8

 Schedule A to Arbitration Agreement 

The following are considered to be Agreements: 

	1.	Renewed and Extended Development and License Agreement 

	2.	[**] 

	3.	[**] 

	4.	[**] 

	5.	[**] 

	6.	[**] 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule G: Arbitration Agreement - 1 January 2013	 	9

 Schedule B to Arbitration Agreement 

In accordance with Article 1.1 of the [**] Rules, in addition to such other modifications of the [**] Rules as are contained in this
Arbitration Agreement, the Parties to this Arbitration Agreement and to the Agreements modify the [**] Rules as follows: 
  

	a)	Notwithstanding Article 3.1 of the [**] Rules, a Notice of Arbitration may be given by any Arbitrating Party to multiple parties so as to join said parties into any
pending arbitration and this Arbitration Agreement shall allow for multi-party arbitration involving third parties, fourth parties and any further additional parties. 

 

	b)	Notwithstanding Article 3.2 of the [**] Rules, arbitral proceedings under this Arbitration Agreement shall be deemed to commence on the date on which the
Claimant’s Notice of Arbitration is received by the [**]. 

  

	c)	Notwithstanding Article 3.3(g), Article 3.4(a) and Article 3.4(b) of the [**] Rules, the Notice of Arbitration shall not contain a proposal as to the number or
appointment or the notification of the appointment of arbitrators (and, if made, any such proposal shall be disregarded). 

  

	d)	Notwithstanding Article 21.3 of the [**] Rules, any Arbitrating Party must make any counter-claim or claim for the purpose of set-off in its statement of defense and
not at a later stage of the arbitral proceedings. 

  

	e)	Notwithstanding Article 22 of the [**] Rules, the arbitral tribunal shall, in considering whether it is appropriate to allow a party to amend or supplement a written
communication (given the interests of economy, efficiency and the desire to avoid the risk of inconsistent awards), have particular regard to the multi-party nature of any arbitration proceeding, the consequences in terms of delay and the objective
of resolving related Claims in a single arbitration involving all relevant Parties. 

  

	f)	Notwithstanding Article 25 of the [**] Rules, in considering whether an extension of a time-limit for the communication of written statements is justified, the arbitral
tribunal shall have particular regard to the multi-party nature of any arbitration proceeding and the consequences in terms of delay. 

  

	g)	Notwithstanding Article 26 of the [**] Rules, no interim measures shall be sought or applied against the BIS in connection with any Dispute by either an arbitral
tribunal established pursuant to this Arbitration Agreement or any judicial authority. 

  

					
	** CONFIDENTIAL PORTION OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
		
	Schedule G: Arbitration Agreement - 1 January 2013	 	1EX-10.9

 Exhibit 10.9 
 CHANGE OF CONTROL RETENTION AGREEMENT 
 This Change of Control Retention
Agreement (“this Agreement”) is made as of the      day of             , 2013, between Digimarc Corporation, an Oregon corporation, with its
principal offices at Beaverton, Oregon (hereinafter called the “Company”), and                      (hereinafter called
“Executive”). 
 It is made with reference to the following facts: 

A. The Board of Directors of the Company (the “Board”) believes it imperative that the Company and the Board be able to rely
upon Executive to continue in Executive’s position, and that they be able to receive and rely upon Executive’s advice as to the best interests of the Company and its shareholders, without concern that Executive might be distracted or his
or her advice affected by the circumstances described in Section 1.2 below; 
 B. [The existing Change of Control Retention
Agreement (the “Existing Agreement”) between the Company and Executive expires by its terms on December 31, 2012;] 
 C. Executive is willing to enter into this Agreement for the purposes and on the terms and conditions described herein; 
 NOW, THEREFORE, the parties hereto agree as follows: 
  

	1.	Definitions 

 1.1
“Approved Group” shall mean any employee benefit plan of the Company or of any subsidiary of the Company, or any person or entity organized, appointed or established by the Company for or pursuant to the terms of any such plan. 

1.2 “Effective Date” shall mean the day preceding the first to occur of the following events (the “Change of Control
Events”): 
 (a) Any Person (as defined in Section 13(d) of the Securities Exchange Act of 1934, as amended (the
“Exchange Act”), other than the Approved Group or a broker, bank, or trust company holding common stock of the Company for the account of customers who are not members of a “group” (within the meaning of Section 13(d) of the
Exchange Act), becoming the record or beneficial owner of 50% or more of any class of the Company’s voting equity securities, as disclosed by the Company’s stock records or in any other way, including, without limitation, any filing with
the Securities and Exchange Commission or otherwise; or 
 (b) Upon the purchase of 50% or more of any class of the
Company’s voting equity securities pursuant to any tender offer or exchange offer for shares of the Company’s stock, other than one made by the Company or the Approved Group; or 

(c) Upon approval by the shareholders of the Company (or, if later, approval by the shareholders of a third party) of any merger,
consolidation, reorganization or other transaction providing for the conversion or exchange of more than fifty percent (50%) of the outstanding shares of the Company’s stock into securities of a third party, or cash, or property, or a
combination of any of the foregoing; or 

  
 -1-

 (d) A transaction or series of related transactions in which assets to which more than 50%
of the Company’s revenues (as measured during the four completed fiscal quarters immediately preceding such transaction or the first in the series of such transactions) are attributable are sold or effectively sold (such as through an exclusive
license or comparable arrangement). 
 1.3 “Fiscal Year” shall mean the 12-month period ending on December 31.

 1.4 “Good Reason,” when used with reference to a voluntary termination by Executive of his or her employment with
the Company, shall mean: 
 (a) a substantial reduction in Executive’s level of duties or responsibilities; provided, that
(i) a change in title or (ii) a change in title or status resulting from the Company, or any affiliate of the Company by which Executive is then employed, being a direct or indirect subsidiary of a parent company following a Change of
Control Event, with no corresponding substantial reduction in Executive’s level of duties and responsibilities, shall not, in and of itself, constitute Good Reason; 
 (b) a material reduction in Executive’s Minimum Base Salary, benefits or total cash compensation (consisting of base salary and target bonus, if any), unless such reduction is part of an overall
reduction for all employees at the same level as Executive; 
 (c) the Company’s mandatory transfer of Executive to another
geographic location that is more than 35 miles from the location where Executive was employed at the Effective Date, except for required travel on the Company’s business to an extent substantially consistent with Executive’s business
travel obligations immediately prior to the Effective Date hereof; 
 (d) the failure by the Company to obtain an assumption of
the obligations of the Company to perform this Agreement by any successor to the Company, to the extent legally required; or 

(e) the repudiation or failure by the Company or its successor to comply with any of its obligations under this Agreement. 

1.5 “Contract Period” shall mean the period commencing on the Effective Date and ending on the first (1st) anniversary of
the Effective Date. 
 1.6 “Disability” shall mean a physical or mental incapacity of Executive which entitles
Executive to commence the receipt of benefits under the long-term disability plan maintained by the Company. 
 1.7
“Cause,” when used in connection with the termination of Executive’s employment by the Company, shall mean (a) the willful engaging by Executive in misconduct which is significantly injurious to the Company, monetarily or
otherwise; (b) any act by the Executive of fraud, dishonesty, embezzlement, misrepresentation or theft of property of the 

  
 -2-

 
Company; (c) Executive’s conviction of or plea of no contest to a felony or any crime involving moral turpitude; (d) Executive’s breach of this Agreement or any other
agreements with the Company; (e) Executive’s unauthorized disclosure of the Company’s proprietary or confidential information or breach of any confidentiality/invention/proprietary information agreement(s) with the Company;
(f) Executive’s violation of the Company’s Code of Ethics (if applicable), Code of Business Conduct and Ethics or any other employment rule, code or policy, as such policies currently exist or may be amended or implemented during
Executive’s employment with the Company; (g) Executive’s failure or refusal to follow the lawful instructions of the Company, if such failure or refusal continues for a period of five (5) calendar days after the Company delivers
to Executive a written notice stating the instructions that Executive has failed or refused to follow; (h) the entry by a court of competent jurisdiction of an order, or the entering into by Executive of a consent decree, barring Executive from
serving as an officer or director of a public company; or (i) Executive’s failure to meet and sustain an acceptable level of performance of Executive’s duties and obligations to the Company (other than by reason of Disability), which
failure continues thirty (30) days after the Company has given written notice thereof to Executive. For purposes of this definition, no act, or failure to act, on Executive’s part shall be considered “willful” unless done, or
omitted to be done, by Executive in bad faith and without reasonable belief that the action or omission was in the best interests of the Company. 
 1.8 “Without Cause,” when used in connection with the termination of Executive’s employment by the company, shall mean any termination of employment of Executive by the Company which is not
a termination of employment for Cause or for Disability. 
 1.9 “Termination Date” shall mean the effective date as
provided in this Agreement for the termination of Executive’s employment. 
 1.10 “Minimum Base Salary” shall
mean salary at an annual rate equal to Executive’s annual rate of salary on the Termination Date (or, if Executive terminates for Good Reason, within the meaning of Section 1.4(b), immediately prior to the material reduction thereof giving
rise to Good Reason). 
 1.11 “Current Compensation” shall mean one-twelfth (1/12th) of the Minimum Base Salary.

  

	2.	Scope of Agreement 

  

	 	2.1	General 

 This Agreement
shall apply with respect to any termination of employment of Executive which occurs during the Contract Period. It shall not apply to any termination of employment of Executive which occurs other than during the Contract Period. 

 

	 	2.2	Termination 

 This
Agreement shall terminate on December 31, 2015, if Executive is still in the employ of the Company and no Contract Period is in process. Except as otherwise provided herein, in respect of payments to beneficiaries, this Agreement shall
terminate automatically upon the death of Executive. 

  
 -3-

	3.	Termination of Employment of Executive By the Company During the Contract Period 

 

	 	3.1	General 

 During the
Contract Period, the Company shall have the right to terminate Executive’s employment hereunder for Cause, for Disability or Without Cause upon following the procedures hereinafter specified. 

 

	 	3.2	For Disability 

Termination of Executive’s employment for Disability shall become effective on the date that disability benefits, payable to
Executive in an amount equal to at least sixty-five (65%) percent of Executive’s then Minimum Base Salary commence under any long-term disability plan maintained by the Company or on such later date as the Company may specify in a written
notice to the Executive. 
  

	 	3.3	For Cause 

 Termination of
Executive’s employment for Cause shall become effective five (5) days after a written notice of intent to terminate Executive’s employment, specifying the particulars of the conduct of Executive forming the basis for such termination,
is given to Executive by the Board. 
  

	 	3.4	Without Cause 

 The
Company shall have the absolute right to terminate Executive’s employment Without Cause at any time. Termination of Executive’s employment Without Cause shall be effective five (5) business days after the date of the giving to
Executive by the Board of a written notice of termination, specifying that such termination is Without Cause. 
  

	 	3.5	Effect of Termination 

Upon a termination of Executive’s employment for Cause, or for Disability as provided in Section 3.2 hereof, Executive shall
have no right to receive any compensation or benefits hereunder. Upon a termination of Executive’s employment Without Cause, Executive shall be entitled to receive the compensation and benefits provided in Section 5 hereof. 

 

	4.	Termination of Employment by Executive During Contract Period 

 During the Contract Period, the Executive shall be entitled to terminate his or her employment with the Company. The Executive shall give the Company written notice of voluntary termination of employment,
which notice need specify only Executive’s desire to terminate his or her employment and, if such termination is for Good Reason, set forth in reasonable detail the facts and circumstances claimed by Executive to constitute Good Reason. Any
notice by Executive pursuant to this Section shall be effective thirty-one (31) days after receipt by the Company of such notice; provided, that Executive’s termination of employment shall not be for Good Reason, if (a) the Company
has, within such thirty (30) days after receiving 

  
 -4-

 
Executive’s notice, corrected the condition that would otherwise result in Good Reason for termination, or (b) Executive fails to give the Company his/her written notice of voluntary
termination of employment within ninety (90) days after the initial existence of such condition. If such termination is for Good Reason, Executive shall be entitled to receive the compensation and benefits in Section 5 hereof. If such
termination is for other than Good Reason, Executive shall have no right to receive any compensation and benefits hereunder other than Executive’s Minimum Base Salary and accrued vacation through Executive’s termination date. 

 

	5.	Benefits Upon Termination by the Company Without Cause or by Executive for Good Reason 

Upon the termination of the employment of Executive by the Company pursuant to Section 3.4 or by Executive for Good Reason pursuant
to Section 4 hereof, and if Executive executes and does not revoke a general release of all claims in a form acceptable to the Company and substantially similar to Exhibit A attached hereto (the “General Release”), which
General Release becomes effective (i.e., the Executive has executed the General Release and any revocation period has expired without Executive revoking the General Release) within forty-five (45) days, or such shorter period as is specified in
the General Release, after the date of Executive’s termination, Executive shall be entitled to receive the following compensation and benefits: 
 5.1 The Company shall pay to Executive (a) Minimum Base Salary through the Termination Date, and (b) for the period commencing on the Termination Date and continuing until the first anniversary
of the Termination Date, a monthly amount equal to the Current Compensation; provided, however, that the Company’s obligation hereunder shall be reduced by the amount of any compensation Executive receives from another source for
services rendered during the period that payments are being made pursuant to this Section 5.1; and provided further that any amount due to Executive under clause (b) during the period from the date of Executive’s termination to the
effective date of the General Release shall be paid to Executive on the first regularly-scheduled pay date coinciding with or immediately following the effective date of the General Release. Executive shall provide notice of all compensation
referred to in the preceding sentence to the Company within seven (7) days of receipt of such compensation. Notwithstanding the foregoing, to the extent necessary to avoid subjecting Executive to the imposition of any additional tax or interest
under Section 409A of the Internal Revenue Code of 1986, as amended (the “Code”), amounts that would (but for this provision) be payable pursuant to clause (b) of the first sentence of this Section 5.1 during the forty-five
(45) day period immediately following the date of Executive’s termination, shall instead be paid in a lump sum on the first regularly-scheduled pay date occurring at least forty-six (46) days after the date of Executive’s
termination. 
 5.2 The Company shall pay any premiums necessary to continue Executive’s health insurance coverage under
the Company’s health insurance plan pursuant to Section 4980B(f) of the Internal Revenue Code of 1986, as amended (“COBRA”) (provided that Executive is eligible for, and timely elects, COBRA continuation coverage under the
Company’s group health plan) until the earliest of (a) eighteen (18) months after the Termination Date, (b) the first date that Executive is covered under another health insurance plan or program, or (c) the date on which
Executive is no longer entitled to COBRA continuation coverage under the Company’s group 

  
 -5-

 
health plan. Notwithstanding the foregoing, the Company may unilaterally amend this Section 5.2 or eliminate the benefit provided hereunder to the extent it deems necessary to avoid the
imposition of excise taxes, penalties or similar charges on the Employer, including, without limitation, under Code Section 4980D. 
 5.3 Notwithstanding any other provision of this Agreement, if the Company receives confirmation from the Company’s independent tax counsel or its certified public accounting firm (the “Tax
Advisor”) that any portion of any payment by the Company or a related entity to Executive, or any benefit received by Executive, under this Agreement or otherwise (each a “Payment”) would be considered to be an “excess parachute
payment” within the meaning of Code Section 280G, then the Payments (under this Agreement or otherwise) shall be reduced (the “Reduction”) to the highest amount that, in the opinion of the Tax Advisor, may be paid to Executive by
the Company without having any portion of any Payment treated as an “excess parachute payment”; provided that the Reduction shall not apply if, in the opinion of the Tax Advisor, the after-tax value to Executive of the total Payments prior
to the Reduction is greater than the after-tax value to Executive if the total Payments are determined taking into account the Reduction. For purposes of determining the after-tax value of the Payments, (i) Executive shall be deemed to pay
income taxes at the highest rate of federal income tax and the highest rate or rates of state and local income taxes in the state and locality of Executive’s domicile for income tax purposes for the taxable year in which the Total Payments will
be made, provided that the state and local income tax rate shall be determined assuming that such taxes are fully deductible for federal income tax purposes, and provided further that any phase-out of itemized deductions or other items shall be
ignored; and (ii) Executive shall be deemed to pay employment taxes at the applicable rate under Code Section 3101(b). The Reduction, if any, shall be applied to the Payments by the Company in its reasonable discretion in the following
order: (a) reduction of any Payments that are subject to Code Section 409A on a pro-rata basis or such other manner that complies with Code Section 409A, as determined by the Company, and (b) reduction of any Payments that are
exempt under Code Section 409A. If the Tax Advisor requests, Executive and the Company shall obtain, at the Company’s expense, and the Tax Advisor may rely on, the advice of a firm of recognized executive compensation consultants as to the
reasonableness of any item of compensation to be received by Executive. All determinations made by the Tax Advisor shall be binding upon the parties hereto and all fees and expenses of the Tax Advisor shall be borne by the Company. 

5.4 Except as specifically provided herein, the amount of any compensation or benefits provided for in this Section 5 shall not be
subject to mitigation by Executive being required to seek other employment or otherwise. 
 5.5 The parties intend that this
Agreement and the payments and other benefits provided hereunder be exempt from the requirements of Code Section 409A to the maximum extent possible, whether pursuant to the short-term deferral exception described in Treasury Regulation
Section 1.409A-1(b)(4), the involuntary separation pay plan exception described in Treasury Regulation Section 1.409A-1(b)(9)(iii), or otherwise. To the extent Code Section 409A is applicable to this Agreement (and such payments and
benefits), the parties intend that this Agreement (and such payments and benefits) comply with the deferral, payout and other limitations and restrictions imposed under Code Section 409A. Notwithstanding any other provision of this Agreement to
the contrary, this Agreement shall be interpreted, operated and 

  
 -6-

 
administered in a manner consistent with such intentions; provided, however that in no event shall the Company or its agents, parents, subsidiaries, affiliates or successors be liable for any
additional tax, interest or penalty that may be imposed on Employee pursuant to Code Section 409A or for any damages incurred by Executive as a result of this Agreement (or the payments or benefits hereunder) failing to comply with, or be
exempt from, Code Section 409A. Without limiting the generality of the foregoing, and notwithstanding any other provision of this Agreement to the contrary; 

(a) to the extent Code Section 409A is applicable to this Agreement, a termination of employment shall not be deemed
to have occurred for purposes of any provision of this Agreement providing for the payment of amounts or benefits upon or following a termination of employment unless such termination is also a “separation from service,” as defined in
Treas. Reg. Section 1.409A-1(h), after giving effect to the presumptions contained therein (and without regard to the optional alternative definitions available therein), and, for purposes of any such provision of this Agreement, references to
“terminate,” “termination,” “termination of employment” and like terms shall mean separation from service; 
 (b) if at the time Executive’s employment hereunder terminates, Executive is a “specified employee” within the meaning of Code Section 409A, then to the extent necessary to avoid
subjecting Executive to the imposition of any additional tax or interest under Code Section 409A, amounts that would (but for this provision) be payable within six (6) months following the date of Executive’s termination of employment
shall not be paid to Employee during such period, but shall instead be paid in a lump sum on the first business day of the seventh month following the date on which Executive’s employment terminates or, if earlier, upon Executive’s death;
and 
 (c) each payment made under this Agreement shall be treated as a separate payment and the right to a
series of installment payments under this Agreement, including, without limitation, under Section 5.1 hereof, shall be treated as a right to a series of separate payments 
 5.6 If Executive does not properly execute the General Release or if Executive revokes or attempts to revoke the General Release or if the General Release is not effective within forty-five
(45) days, or within such shorter period specified in the General Release, after Executive’s termination of employment, Executive will not be entitled to any of the benefits provided under this Section 5, except those which may be
otherwise required by law. 
  

	6.	Successors; Binding Agreement 

 6.1 As used in this Agreement, “Company” shall mean the Company as hereinbefore defined and any successor to its business and/or assets or which otherwise becomes bound by all the terms and
provisions of this Agreement by operation of law. 
 6.2 This Agreement is personal to Executive and Executive may not assign or
transfer any part of his or her rights or duties hereunder, or any compensation due to Executive hereunder, to any other person, except that this Agreement shall inure to the benefit of and be enforceable by Executive’s personal or legal
representatives, executors, administrators, heirs, distributees, devisees, legatees or beneficiaries. 

  
 -7-

	7.	Modification; Waiver 

 No
provisions of this Agreement may be modified, waived or discharged unless such waiver, modification or discharge is agreed to in writing signed by Executive and by the Chief Executive Officer of the Company or such other director or officer as may
be specifically designated by the Board. Waiver by any party of any breach of or failure to comply with any provision of this Agreement by the other party shall not be construed as, or constitute, a continuing waiver of such provision, or a waiver
of any other breach of, or failure to comply with, any other provision of this Agreement. 
  

	8.	Arbitration of Disputes 

8.1 Any disagreement, dispute, controversy or claim arising out of or relating to this Agreement or the interpretation or validity hereof
shall be settled exclusively and finally by arbitration. It is specifically understood and agreed that any disagreement, dispute or controversy which cannot be resolved between the parties, including, without limitation, any matter relating to the
interpretation of this Agreement, may be submitted to arbitration irrespective of the magnitude thereof, the amount in controversy or whether such disagreement, dispute or controversy would otherwise be considered justiciable or ripe for resolution
by a court or arbitral tribunal. 
 8.2 The arbitration shall be conducted in accordance with the Commercial Arbitration Rules
(the “Arbitration Rules”) of the American Arbitration Association (the “AAA”). 
 8.3 The arbitral tribunal
shall consist of one arbitrator. The parties to the arbitration jointly shall directly appoint such arbitrator within thirty (30) days of initiation of the arbitration. If the parties shall fail to appoint such arbitrator as provided above,
such arbitrator shall be appointed by the AAA as provided in the Arbitration Rules and shall be a person who (a) maintains his or her principal place of business in the State of Oregon; and (b) has had substantial experience in business
transactions. The Company shall pay all of the fees, if any, and expenses of such arbitrator. 
 8.4 The arbitration shall be
conducted in Portland, Oregon, or in such other city in the United States of America as the parties to the dispute may designate by mutual written consent. 
 8.5 At any oral hearing of evidence in connection with the arbitration, each party thereto or its legal counsel shall have the right to examine its witnesses and to cross-examine the witnesses of any
opposing party. No evidence of any witness shall be presented in written form unless the opposing party or parties shall have the opportunity to cross-examine such witness, except as the parties to the dispute otherwise agree in writing or except
under extraordinary circumstances where the interests of justice require a different procedure. 
 8.6 Any decision or award of
the arbitral tribunal shall be final and binding upon the parties to the arbitration proceeding. The parties hereto hereby waive to the extent permitted by law any rights to appeal or to seek review of such award by any court or tribunal. The
parties 

  
 -8-

 
hereto agree that the arbitral award may be enforced against the parties to the arbitration proceeding or their assets wherever they may be found and that a judgment upon the arbitral award may
be entered in any court having jurisdiction. 
 8.7 Nothing herein contained shall be deemed to give the arbitral tribunal any
authority, power, or right to alter, change, amend, modify, add to, or subtract from any of the provisions of this Agreement. 
  

	9.	Payment Obligations Absolute 

 The Company’s obligation to pay Executive the amounts provided for hereunder and to make the arrangements provided for hereunder shall be absolute and unconditional and shall not be affected by any
circumstances, including, without limitation, any set-off, counterclaim, recoupment, defense or other right which the Company may have against Executive or anyone else. All amounts payable by the Company hereunder shall be paid without notice or
demand. Except as expressly provided herein, the Company waives all rights which it may now have or may hereafter have conferred upon it, by statute or otherwise, to terminate, cancel or rescind this Agreement in whole or in part. Subject to the
right of the Company to seek arbitration under Section 8 and recover, pursuant to such arbitration, any payment made hereunder, each and every payment made hereunder by the Company shall be final and the Company will not seek to recover all or
any part of such payment from Executive or from whomsoever may be entitled thereto, for any reason whatsoever. 
  

	10.	Notice 

 All notices,
requests, demands and other communications required or permitted to be given by either party to the other party by this Agreement (including, without limitation, any notice of termination of employment and any notice under the Arbitration Rules of
an intention to arbitrate) shall be in writing and shall be deemed to have been duly given when delivered personally or received by certified or registered mail, return receipt requested, postage prepaid, at the address of the other party as
follows: 
 If to the Company, to: 
 Digimarc Corporation 
 9405 S.W. Gemini Drive 

Beaverton, Oregon 97008 
 Attn: Chief Legal Officer 
 If to the Executive, to: 

 

							
	  
	 		 		 	
	  
	 		 		 	
	  
	 		 		 	
	  
	 		 		 	

 Either party hereto may change its address, for purposes of this Section 10, by giving fifteen (15) days prior
notice to the other party hereto. 

  
 -9-

	11.	Severability 

 If any term
or provision of this Agreement or the application hereof to any person or circumstances shall to any extent be invalid or unenforceable, the remainder of this Agreement or the application of such term or provision to persons or circumstances other
than those as to which it is held invalid or unenforceable shall not be affected thereby, and each term and provision of this Agreement shall be valid and enforceable to the fullest extent permitted by law. 

 

	12.	Headings 

 The headings in
this Agreement are inserted for convenience of reference only and shall not be a part of or control or affect the meaning of this Agreement. 
  

	13.	Counterparts 

 This
Agreement may be executed in several counterparts, each of which shall be deemed an original. 
  

	14.	Governing Law 

 This
Agreement shall in all respects be governed by, and construed and enforced in accordance with, the laws of the State of Oregon. 
  

	15.	Payroll and Withholding Taxes 

 All payments to be made or benefits to be provided hereunder by the Company shall be subject to reduction for any applicable payroll related or withholding taxes. 

 

	16.	Entire Agreement 

 This
Agreement supersedes any and all other oral or written agreements heretofore made relating to the subject matter hereof and constitutes the entire agreement of the parties relating to the subject matter hereof; provided, that this Agreement
shall not supersede or limit or in any way affect any rights Executive may have under any other Company employee benefit plan, program or arrangement (including, without limitation, any pension, life insurance, medical, dental, health, vacation,
accident and disability plans, programs and arrangements). 
 IN WITNESS WHEREOF, the parties have executed this Change of
Control Retention Agreement as of the date first above written. 
  

									
	EXECUTIVE	 		 	DIGIMARC CORPORATION
					
	By:	 	  
	 		 	By:	 	  

		 		 		 	Name:	 	  

		 		 		 	Title:	 	  

  
 -10-

 EXHIBIT A 
 SETTLEMENT AGREEMENT AND GENERAL RELEASE 
 This SETTLEMENT AGREEMENT AND
GENERAL RELEASE (this “Agreement”), effective             , 20     by and between
                     (“Executive”) and Digimarc Corporation (the “Company”) 

RECITAL 

A. Executive and Company are parties to, among other things, a Change of Control Retention Agreement dated as of January 1, 2013
(the “Change of Control Retention Agreement”). 
 B. The Change of Control Retention Agreement provides, among
other things, that if (i) Company terminates the employment of Executive Without Cause (as defined in the Change of Control Retention Agreement), or (ii) the Executive resigns his or her employment for Good Reason (as defined in the Change
of Control Retention Agreement) (each a “Release Condition”), then Executive shall execute this Agreement in exchange for the right to receive certain payments from Company as set forth more fully in the Change of Control Retention
Agreement. 
 C. Effective             ,
200    , a Release Condition has occurred. 
 AGREEMENT 

In consideration of the foregoing premises, the mutual covenants and agreements contained herein, and other good and valuable
consideration, the receipt and sufficiency of which are hereby acknowledged, the parties hereto agree as follows: 
 1.
Settlement Amount. Execution of this Agreement by Executive shall satisfy the condition that Executive execute a full release of claims as set forth in Section 5 of the Change of Control Retention Agreement and, upon satisfaction of any
other conditions set forth in this Agreement or in the Change of Control Retention Agreement, Executive shall be entitled to receive the compensation set forth in Section 5 of the Change of Control Retention Agreement. 

2. Release of Claims. Executive irrevocably and unconditionally releases and forever discharges Company, its affiliates,
successors and assigns, and each of their respective officers, directors, members, employees, representatives, insurance carriers, attorneys, subsidiaries, affiliates, representatives, agents, successors, heirs, executors, administrators and
assigns, and all persons acting by, through, under or in concert with any of them (collectively “Releasees”), of and from any and all claims, actions, causes of action, suits, debts, charges, complaints, liabilities, obligations, promises,
agreements, controversies, damages, and expenses (including attorney’s fees and costs actually incurred), of any nature whatsoever, known or unknown, in law or equity, including, without limitation of the foregoing general terms, any claims
against Company and Releasees arising from or related to Executive’s employment with 

  
 -11-

 
Company or the termination thereof, and any claims arising from any alleged violation by Company of any federal, state or local statutes, ordinances or common laws, including, but not limited to,
the Age Discrimination in Employment Act. 
 3. Confidentiality. Executive agrees that the terms, amount and fact of
settlement shall be kept strictly confidential and promises that neither Executive nor Executive’s representatives nor agents shall disclose, either directly or indirectly, any information concerning this settlement (or the fact of settlement)
to anyone, including but not limited to past, present or future employees of Company, its affiliates, successors or any other company. 
 4. Disclaimer of Liability. This Agreement does not constitute and shall not be construed as an admission of liability or wrongdoing by Company, its agents, employees or successors, with respect to
any claims asserted by Executive, and Company expressly denies that it has done anything wrong or unlawful. 
 5. Release of
Unknown Claims. Executive represents that Executive is not aware of any claims against Company except for those claims that are released by this Agreement. Moreover, the Parties agree and represent that it is within their contemplation that
Executive may have claims against Company of which, at the time of the execution of this Agreement, they have no knowledge or suspicion, but that this Agreement extends to claims in any way based upon, connected with, or related to the matters
described in Paragraph 2 above, whether or not known, claimed, or suspected by the Parties. 
 6. Property. As a
precondition to any settlement payment in connection with this Agreement, Executive shall return to Company all property of Company in Executive’s possession. 
 7. ADEA Notification. This Agreement contains a release of claims under the Age Discrimination in Employment Act (the “ADEA”). By executing this Agreement, Executive certifies that
Executive has knowingly and voluntarily given up any claims that Executive may have under the ADEA if those claims arose before Executive signed this Agreement. Executive further certifies that the payments described in this Agreement are
considerations to which Executive would not otherwise be entitled without signing this Agreement, and that these considerations constitute payment in exchange for Executive’s execution of this Agreement. 

Under the ADEA, Executive may take up to twenty-one (21) days to consider the terms of this Agreement. Executive has the right to
accept in less time by signing and delivering this Agreement to Company. Executive is urged to use as many of the twenty-one (21) days as necessary to consider this Agreement and to consult with Executive’s attorney about it. Executive
acknowledges that Executive has been given at least twenty-one (21) days to consider this Agreement prior to signing it, and Executive’s signature on this Agreement is completely voluntary. 

Under the ADEA, Executive may revoke this Agreement within seven (7) days of the date on which Executive signs the Agreement. If
Executive revokes, then Executive will not receive any of payments or other considerations set forth in this Agreement. TO BE EFFECTIVE, EXECUTIVE’S REVOCATION MUST BE IN WRITING AND

  
 -12-

 
RETURNED TO DIGIMARC CORPORATION, ATTENTION: CHIEF LEGAL OFFICER, WITHIN SEVEN (7) DAYS OF THE DATE OF EXECUTIVE’S SIGNING OF THIS AGREEMENT. 

8. Governing Law. This Agreement shall be governed by and construed under the laws of the State of Oregon as applied to agreements
among Oregon residents, made and to be performed entirely within the State of Oregon, without giving effect to conflicts of laws principles. 

PLEASE READ CAREFULLY. THIS IS A RELEASE OF CLAIMS YOU MAY HAVE AGAINST DIGIMARC CORPORATION. 

 

									
	EXECUTIVE	 		 	DIGIMARC CORPORATION
					
	By:	 	  
	 		 	By:	 	  

		 		 		 	Name:	 	
		 		 		 	Title:	 	
			
	Dated:             , 20    	 		 	Dated:             , 20    

  
 -13-

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00213-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00213-of-00352.parquet"}]]