Document:

EX-10.2

 Exhibit 10.2 
 SLSI-201304IA001-1 
 FOUNDRY SERVICES AGREEMENT 

This Foundry Services Agreement (“Agreement”) is entered into on 27th June, 2013 (the “Effective Date”) by and
between Samsung Electronics Co., Ltd., a company duly incorporated under the laws of the Republic of Korea, acting through its System LSI Division, with principal offices located at San #24, Nonseo-Dong, Giheung-Gu, Yongin-City, Gyeonggi-Do, 449-711
Korea (“Samsung” or “Seller”), and IXYS Intl Limited, a corporation organized under the laws of the Cayman Islands, with a principal place of business at the offices of Intertrust Cayman Islands, 190 Elgin Avenue, George Town,
Grand Cayman, KY1-9005 Cayman Islands (“IXYS” or “Purchaser”). 
 RECITALS 

WHEREAS, Samsung and IXYS are parties to that certain Asset Purchase Agreement dated on May 25th, 2013 (the
“APA,” Samsung document number SLSI-201304IA001) pursuant to which, among other things, IXYS is purchasing or otherwise acquiring rights relating to the Business (as defined in the APA) pursuant to a series of transactions
contemplated in the APA (collectively, the “Transaction”); 
 WHEREAS, in connection
with the Transaction, the parties have agreed that, commencing on the Effective Date, Samsung will provide certain manufacturing services for the Business Products (as defined in the APA) to IXYS using Samsung’s *** process ***; and 

WHEREAS, in connection with the Transaction, IXYS desires Samsung to manufacture and supply Business Products to
IXYS as more fully described in an applicable Foundry Project Statement and Samsung desires to provide such manufacturing services to IXYS in accordance with the terms and conditions set forth in this Agreement. 

NOW, THEREFORE, in consideration of the promises set forth herein, and for other good and valuable considerations,
the parties hereby agree as follows: 
 AGREEMENT 

 

	1	 Definitions 

 Unless otherwise defined in this Section 1, any capitalized terms used in this Agreement will have the meanings set forth in the APA and shall apply to both their singular and plural forms, as the
context may require. 
  

	1.1	 “Confidential Information” shall mean all business, financial, contractual, marketing and/or other technical or non-technical
information, in whatever form, which is disclosed, or to which access is provided under and/or in furtherance of this Agreement, by a party hereto (“Discloser”) to the other party to this Agreement (“Recipient”),
which (a) if in writing, is marked as “confidential”, “proprietary” or other similar marking at the time of disclosure, (b) if provided orally, visually or in any other form (except in writing) such as sample products
or test boards, is identified as confidential at the time of disclosure and confirmed in writing to Recipient within thirty (30) days of such disclosure, or (c) would reasonably be deemed in the context of its disclosure to be confidential
or proprietary. 

  
 ***Certain confidential
information contained in this document, marked with 3 asterisks (***), has been omitted and filed separately with the Securities and Exchange Commission pursuant to Rule 24b-2 of the Securities Exchange Act of 1934, as amended. 

  
 Page 1 / 24

 Confidential 

 SLSI-201304IA001-1 

 
  

	1.2	 “IXYS Background IP” shall mean all Intellectual Property in or to any IXYS Deliverables, owned by IXYS and/or its licensors
(excluding Samsung) 

  

	1.3	 “IXYS Business Products” means all products manufactured under the *** process and/or provided by Samsung to IXYS under this
Agreement that are IXYS versions of the Business Products and substantially the same as one of the Business Products. 

  

	1.4	 “IXYS Deliverables” shall mean any information and materials provided to Samsung by IXYS to be utilized by Samsung in the
development and/or fabrication of and/or incorporation into the Product hereunder, including, without limitation, software, schematics, netlists, microcode, GDSII data, designs or techniques, including those identified as such in the applicable SOW.

  

	1.5	 “Delivery Date” means the scheduled delivery date of Product set forth in the applicable Purchase Order issued by IXYS and accepted
by Samsung under this Agreement. 

  

	1.6	 “Die” means an individual integrated circuit or components of a Product which when completed create an integrated circuit.

  

	1.7	 “Engineering Sample” shall mean sample Product(s) in wafer, Die or Package form provided to IXYS for purposes of promotion,
evaluation and verification of a revised mask set. 

  

	1.8	 “Manufacturing Window” means the period of time prior to the Delivery Date which is equal to the Standard Lead Time.

  

	1.9	 “Mask and Prototyping Services” shall mean all engineering services provided under this Agreement by Samsung to IXYS as more fully
set forth in Section 2 below and in the applicable SOW. 

  

	1.10	 “Monthly Wafer Limit” shall mean *** wafers per month from the Effective Date until the date four years thereafter.

  

	1.11	 “Package” shall mean a encapsulated casing of a Die providing an electronic connecting path to external circuits from the
encapsulated Die, when all assembly processes are complete. 

  

	1.12	 “Product” shall mean an IXYS Business Product, in wafer, Die or Package form, manufactured under this Agreement as more fully set
forth in the Foundry Project Statement. Each Product may contain Samsung Deliverables and/or IXYS Deliverables and have a new product name different from that of the Business Product. 

 

	1.13	 “Product Specification” shall mean the specifications for the Product or revision target to the Product set forth in Annex A of
each Revision Project Statement, which shall be mutually agreed in writing by the parties prior to the signing of each Revision Project Statement. 

  

	1.14	 “Revision Project Statement” shall mean a project statement document executed by both parties specific to a particular Product as
set forth in Section 2 of this Agreement that will include a description of Mask and Prototyping Services, Product Specification, SOWs, Mask and Prototyping Fees and/or other provisions, as applicable. 

 
 ***Certain confidential information contained in this document, marked with 3
asterisks (***), has been omitted and filed separately with the Securities and Exchange Commission pursuant to Rule 24b-2 of the Securities Exchange Act of 1934, as amended. 

  
 Page 2 / 24

 Confidential 

 SLSI-201304IA001-1 

 
  

	1.15	 “Foundry Project Statement” shall mean a project statement document executed by both parties that makes reference to this Agreement
and that will include a description of Product, SOWs, Product Price, yield assumption and/or other provisions, as applicable. 

  

	1.16	 “Project Results” shall mean the results and items set forth in the SOW which arise out of the Mask and Prototyping Services
performed by Samsung for IXYS hereunder for delivery to IXYS. 

  

	1.17	 “Samsung Background IP” shall mean all Intellectual Property in or to any Samsung Deliverables, owned by Samsung and/or its
licensors (excluding IXYS), including, without limitation, those contained in processes, libraries, cells, design kits, and the technologies and information disclosed to IXYS under this Agreement. 

 

	1.18	 “Samsung Deliverables” shall mean any information and materials supplied and/or licensed to IXYS by Samsung, to be utilized by IXYS
in the development of or otherwise incorporated into the Product hereunder, including, without limitation, relevant documentations, software, schematics, netlists, microcode, designs, processes, libraries, cells, and/or design kits, including those
set forth in SOW. 

  

	1.19	 “Statement of Work” or “SOW” shall mean the statement of work shown in Annex B of the Revision Project Statement,
which sets forth a description of the estimated work to be performed by the parties for Mask and Prototyping Services thereunder. 

  

	1.20	 “Standard Lead Time” means the lead time mutually agreed upon by the parties and set forth in each Purchase Order.

  

	2	 Mask and Prototyping Services 

  

	2.1	 In the event that IXYS decides to revise the design of a Product and/or replace the mask set of a Product, in whole or in part, due to bug fixes,
customer requests or otherwise, Samsung will provide the Samsung Deliverables set forth in the SOW of the applicable Revision Project Statement. IXYS shall redesign certain parts of such Product based on and in accordance with Samsung Deliverables,
provide the resulting design data in GDSII form to Samsung, and reasonably assist Samsung with manufacturing Engineering Samples hereunder. Subject to IXYS’ payment of Mask and Prototyping Fees as set forth in Section 6.1, Samsung shall
make the revised mask set, and manufacture and provide to IXYS the number of Engineering Samples set forth in the SOW of the applicable Revision Project Statement. Such Mask and Prototyping Services may include, but not be limited to, physical
verification, tape-out, wafer fabrication and/or Engineering Sample delivery, as more fully set forth in the applicable SOW. Detailed terms and schedules of the Mask and Prototyping Services for a particular Product shall be set forth in the
applicable Revision Project Statement. 

  

	2.2	 Upon receipt of the Engineering Sample, IXYS shall have *** days to evaluate whether such Engineering Sample conforms to the Product Specification
(“ES Acceptance Period”). If the Engineering Sample conforms to the Product Specifications, as determined by IXYS in its reasonable, good faith judgment, IXYS shall accept such Engineering Sample and notify Samsung in writing
thereof. If the Engineering Sample does not conform to the Product Specifications, IXYS shall notify Samsung thereof in writing within the ES Acceptance Period with a detailed description of the non-conformity to be fixed. If such non-conformity is
solely attributable to Samsung, Samsung shall, at 

  

***Certain confidential information contained in this document, marked with 3 asterisks (***), has been omitted and filed separately with the Securities
and Exchange Commission pursuant to Rule 24b-2 of the Securities Exchange Act of 1934, as amended. 

  
 Page 3 / 24

 Confidential 

 SLSI-201304IA001-1 

 

	 	 
its cost, fix such non-conformity, and manufacture an additional Engineering Sample, and deliver such Engineering Sample to IXYS. If such non-conformity is not attributable to Samsung, IXYS
shall, at its cost, fix such non-conformity, and Samsung shall, within the scope of Samsung’s responsibility defined in the Revision Project Statement, and IXYS’s expense, provide reasonable collaboration to IXYS to fix such
non-conformity, manufacture an additional Engineering Sample, and deliver such Engineering Sample to IXYS. For clarity, if IXYS does not provide any notice of non-conformity within the ES Acceptance Period, the applicable Engineering Sample shall be
deemed to be accepted by IXYS, and Samsung shall be under no obligation to fix any non-conformity with respect to such Engineering Sample thereafter. 

  

	2.3	 Samsung shall deliver the Engineering Sample(s) on EXW basis per Incoterms 2010, at an international airport in Korea agreed in writing by the
parties. Title to and risk of loss of the Engineering Sample(s) will transfer upon delivery thereof in accordance with the foregoing sentence. 

  

	2.4	 If the Engineering Sample(s) conforms to the Product Specification pursuant to Section 2.2, the parties shall discuss in good faith on whether
the Product is ready to be manufactured in commercial volumes. 

  

	3	 Commercial Production 

  

	3.1	 In the event that both parties determine that the Product is ready to be manufactured in commercial volumes, IXYS shall provide Samsung with rolling
demand forecasts for the delivery of each Product (“Forecast”). Particularly, IXYS shall provide two types of non-binding Forecasts. 

  

	 	3.1.1	Long Term Forecast. The “Long Term Forecast” is a non-binding, good-faith estimate, at the time such Forecast is made, of IXYS’ demand of each
Product described on a monthly basis for the following *** month period. The Long Term Forecast shall be provided by IXYS to Samsung no later than the *** day of every calendar month, and is provided for the purpose of assisting Samsung in its
long-range planning for manufacturing capacity and capital needs to meet such Long Term Forecast. 

  

	 	3.1.2	Short Term Forecast. The “Short Term Forecast” is a non-binding (unless accepted by Samsung as detailed in Section 3.1.3) good faith estimate, at
the time such Short Term Forecast is made, of IXYS’ demand of each Product described on a weekly basis for the following *** month (n+***) period. IXYS shall provide Samsung with the Short Term Forecast no later than the *** day of each month.

  

	 	3.1.3	Within *** calendar days of receipt of the Short Term Forecast, Samsung shall respond to IXYS in writing on whether it accepts such Short Term Forecast. Once accepted
by Samsung, the Short Term Forecast shall become binding on both parties. Samsung shall accept all Short Term Forecasts that are consistent with the Monthly Wafer Limit. If Samsung fails to respond to a Short Term Forecast within the foregoing
***-calendar day period, then such Short Term Forecast shall be deemed to have been accepted by Samsung. 

  

	 	3.1.4	If the purchase volume ordered by Purchase Order is less than *** of the quantities set forth in the Short Term Forecast, IXYS shall pay to Samsung within *** days of
the applicable Purchase Order date an amount equal to *** of the purchase price (set forth in the Foundry Project Statement) for each unit of such purchase shortfall. Any such payment shall be compensation in full for such purchase shortfall.

  
 ***Certain confidential information contained in
this document, marked with 3 asterisks (***), has been omitted and filed separately with the Securities and Exchange Commission pursuant to Rule 24b-2 of the Securities Exchange Act of 1934, as amended. 

  
 Page 4 / 24

 Confidential 

 SLSI-201304IA001-1 

 
  

	3.2	 IXYS may request to shorten Standard Lead Time of Product. Upon such request of IXYS, Samsung will evaluate the request and use its commercially
reasonable effort to accept, at its sole discretion, IXYS’ request within Samsung’s ‘hot-lot’ capability; provided that Samsung may request additional charge for the shortening of Standard Lead Time and the target lead time shall
be discussed by parties prior to the acceptance of such request. 

  

	3.3	 At any time prior to the date that is three (3) business days prior to the scheduled wafer start of any Product set forth in a applicable
Purchase Order, IXYS may change, on a lot-by-lot basis, the priority of fab-in sequence of such Product within such Purchase Order, without charge, upon notice to Samsung. Samsung shall provide IXYS with a written acknowledgement of such notice
within two (2) business days after Samsung’s receipt of such notice. 

  

	3.4	 It is agreed and understood that the purchase of Products pursuant to this Agreement shall be accomplished by means of IXYS individual purchase
orders (collectively referred to as “Purchase Orders”). 

  

	 	3.4.1	The Purchase Orders shall contain applicable Product quantities, whether the product will be in wafer, Die or Package form, at a price per Product consistent with
Section 1 of Annex B of the Foundry Project Statement (“Product Price”) and a mutually agreed Delivery Date. IXYS shall provide Purchase Orders with at least the quantity set forth in the then current Short Term Forecast
provided by IXYS and accepted by Samsung. Samsung shall accept all Purchase Orders with quantities no greater than the quantities set forth in such Short Term Forecast, but Samsung shall not be obligated to accept any quantities exceeding those set
forth in such Short Term Forecast and, notwithstanding any other provision of this Agreement, any quantities of a Product set forth in a Purchase Order in excess of the Monthly Wafer Limit. The parties shall have a good faith discussion on
accommodating quantities exceeding those set forth in such Short Term Forecast or such Monthly Wafer Limit. 

  

	 	3.4.2	The Purchase Orders shall contain, at a minimum, a quantity of *** wafers per each Product and multiples of *** wafers. 

 

	3.5	 Samsung will manufacture the Products in accordance with the Purchase Order accepted by Samsung and will deliver such Products by the Delivery Date.
Any delivery or shipment made within fourteen (14) calendar days before or after the Delivery Date(s) specified in the Purchase Orders shall constitute timely delivery or shipment. If, in the case of any Purchase Order, Samsung is unable to
ship Products on the scheduled Delivery Date, Samsung shall notify IXYS in writing as soon as reasonably possible thereof and the parties shall discuss to agree upon a mutually acceptable rescheduled Delivery Date. In the event of any such delay is
solely attributable to Samsung or its subcontractor’s fault, Samsung will, at its cost, expedite shipping for any late deliveries using shippers reasonably acceptable to IXYS. 

 

	3.6	 If the cumulative quantity shipped by Samsung of each Product ordered by IXYS is within +/- ten (10) percent of the quantity in the effective
Purchase Order, such quantity shall constitute compliance with such Purchase Order. Billing for partial orders shipped as described in this paragraph shall be at the established purchase price per unit times the total quantity of units delivered.

  

	3.7	 After second anniversary of the Effective Date, Samsung may discontinue the production of each Product upon six (6) month prior notice if IXYS
has not issued Purchase Orders for such Product i) for 

  
 ***Certain confidential information contained in this document, marked with 3 asterisks (***), has been omitted and filed separately with the Securities and Exchange Commission pursuant to Rule 24b-2 of
the Securities Exchange Act of 1934, as amended. 

  
 Page 5 / 24

 Confidential 

 SLSI-201304IA001-1 

 

	 	 
six (6) months prior to such notice; or ii) amounting to at least *** U.S. Dollars ($***USD) during the previous one (1) year period. Samsung shall, in its sole discretion, provide a
Last Time Buy (“LTB”) date and Last Ship Date (“LSD”) in such discontinuation notice. IXYS may issue to Samsung a one-time Purchase Order for such Product as a LTB within *** month after the date of such Samsung discontinuation
notice. If there is no response within *** month after such discontinuation notice, then Samsung reserves the right to discontinue the production of such Product and destroy the mask set for such Product. 

 

	3.8	 Samsung shall deliver Products on EXW basis per Incoterms 2010 to IXYS, at an international airport in Korea agreed in writing by the parties. Title
to and risk of loss of the Products will transfer upon delivery thereof in accordance with the foregoing sentence. 

  

	3.9	 Prior to Samsung’s start of production, IXYS may cancel the Purchase Order at any time without any charge. After Samsung starts production of
applicable Products in accordance with a Purchase Order, IXYS may cancel the Purchase Orders for such Products but shall pay Purchase Price for such Products as cancellation charges as follows : 

 

					
	Cancellation Period	 	Liability

	 	Package business	 	  Wafer or Die 
business  
	Prior to the initiation of
Manufacturing Window	 	No Liability	 	No Liability
	 Initiation of Manufacturing Window ~
  Before contact step
	 	*** of Product Price	 	*** of Product Price
	On and after contact photo
step ~ Before EDS test step	 	*** of Product Price	 	*** of Product Price
	 On and after EDS test step ~
 Before assembly step
	 	*** of Product Price	 	*** of Product Price
	 On and after assembly step
  
	 	 *** of Product Price

 
	 	 -

 

  

	3.10	 IXYS may reschedule the Delivery Date set forth in each Purchase Order subject to the following limitations: 

 

	 	a)	 Within *** days before the Delivery Date - no reschedules permitted. 

	 	b)	 Within *** days but greater than *** days before the Delivery Date – *** of the order may be rescheduled one time only - for no more than ***
days. 

	 	c)	 Within *** days but greater than *** days before the Delivery Date – *** of the order may be rescheduled one time only - for no more than ***
days 

	 	d)	 Reschedule requests are limited to *** per month. 

 

	3.11	 Samsung reserves the right to make any and all reasonable changes to the process(es) required to manufacture the Products and will notify IXYS of
such changes within reasonable time after such changes were made, subject to the Samsung’s internal engineering change notice (ECN) rule. 

  

	3.12	 Notwithstanding anything contrary to this Agreement, Samsung may, after the Effective Date, deliver to IXYS based on a Purchase Order completed
Business Products that were under fabrication on the 

  
 ***Certain confidential information contained in this document, marked with 3 asterisks (***), has been omitted and filed separately with the Securities and Exchange Commission pursuant to Rule 24b-2 of
the Securities Exchange Act of 1934, as amended. 

  
 Page 6 / 24

 Confidential 

 SLSI-201304IA001-1 

 

	 	 
Effective Date, as if such Business Products were Products covered by this Agreement. 

  

	3.13	 Samsung shall destroy or recycle and properly dispose of all scrap related to Products supplied to IXYS hereunder in such a way as to prevent any
unauthorized sale of any such Products. 

  

	3.14	 Notwithstanding anything to the contrary in this Agreement, Samsung shall, after the Effective Date, deliver to IXYS work-in-progress Business
Products that were (i) under fabrication to fulfill Samsung customer orders for Business Products accepted by Samsung prior to the Effective Date (“Customer POs”); (ii) under fabrication on the Effective Date;
(iii) manufactured under ***; and (iv) identified by parties before the Effective Date (“WIP Products”). Samsung will deliver the WIP products to IXYS hereunder, as if such WIP Products were Products covered by this
Agreement, and IXYS shall issue a Purchase Order for all such WIP Products; provided that i) IXYS has no forecasting obligation with respect to the WIP Products pursuant to Section 3.1; ii) the foregoing IXYS Purchase Order shall be a binding
Purchaser Order upon Samsung’s receipt and iii) the WIP Products shall be treated as Products after receipt of the Purchase Order. The Customer POs will be transferred and assigned to IXYS after Effective Date pursuant to the Transition
Services Agreement, and IXYS shall thereafter have all responsibility and liability for fulfilling the Customer POs. 

  

	4	 Electrical Die Sorting (“EDS”) and Back End Process 

 

	4.1	 Samsung will deliver the Product without any EDS tests in wafer form; provided that, subject to mutual consent, Samsung may deliver the Product that
has been sorted in accordance with Samsung’s EDS criteria. 

  

	4.2	 After written notice by Samsung, Samsung may engage its affiliates or third parties to perform certain ancillary service to the manufacturing
services contemplated in this Agreement such as sorting, assembly, sorting or packaging of Die, In the event that Samsung performs foregoing services, the Packages where all process are complete will delivered to IXYS on EXW basis per Incoterms 2010
by Samsung or its subcontractor; provided that Samsung shall be responsible for the act or omission of any of its subcontractors hereunder. If any such subcontracting involves the disclosure of any Confidential Information of IXYS, Samsung will
disclose IXYS’ Confidential Information to such contractors only under a non-disclosure agreement no less strict than this Agreement. 

  

	4.3	 Upon the written request of IXYS, Samsung will transport and deliver Products on EXW basis per Incoterms 2010 to IXYS’ chosen assembly, test,
marking and packaging facilities at an international airport in Korea agreed in writing by the parties. Samsung has no liability for such assembly, test or packaging process performed by IXYS’ subcontractor under this Agreement; provided that
Samsung may assist with the foregoing procedure in connection with the Transition Services Agreement. 

  

	5	 Ownership of Intellectual Property Rights 

  

	5.1	 IXYS shall own and retain all right, title and interest in and to IXYS Background IP. Samsung may use the IXYS Deliverables, solely to perform the
Mask and Prototyping Services hereunder, and/or to manufacture Products solely for IXYS. Samsung shall not use the IXYS Deliverables to design, fabricate, test or otherwise modify Samsung’s own products or other products(s) that are for its
customers other than IXYS unless otherwise specifically agreed by parties in writing. 

  
 ***Certain confidential information contained in this document, marked with 3 asterisks (***), has been omitted and filed separately with the Securities and Exchange Commission pursuant to Rule 24b-2 of
the Securities Exchange Act of 1934, as amended. 

  
 Page 7 / 24

 Confidential 

 SLSI-201304IA001-1 

 
  

	5.2	 Samsung shall own and retain all right, title and interest in and to Samsung Background IP. Unless otherwise specifically agreed by the parties in
writing, all Intellectual Property in or to all modifications and improvements to, or arising from, Samsung Deliverables are the exclusive property of Samsung and all right, title and interest in and to the same vests solely in Samsung, and IXYS may
use Samsung Deliverables solely to perform its rights and obligations hereunder. IXYS shall not use Samsung Deliverables to design, fabricate, test or otherwise modify products(s) that are not fabricated by Samsung or an agent of Samsung unless
otherwise specifically agreed by the parties in writing. 

 IXYS further agrees that
Engineering Samples are provided for testing, evaluation, promotion and verification purposes. For clarity, Engineering Samples are provided “AS IS,” without any warranty of any kind whatsoever. For clarity, Sections 4, 10.2 and 12.1 shall
not apply to Engineering Samples. 
  

	5.3	 Samsung shall retain all right, title and interest in and to masks made by Samsung and/or Samsung’s contractors for use in the fabrication of
Products, but shall use such masks solely to manufacture Products for IXYS. For the avoidance of doubt, the foregoing provision shall not be deemed a transfer of any Intellectual Property rights embodied in the masks. 

 

	5.4	 Unless otherwise expressly set forth in this Agreement or agreed in writing between the parties, no license with respect to either party’s
Intellectual Property is hereby granted. 

  

	6	 Payment 

  

	6.1	 In consideration of Samsung’s Mask and Prototyping Services set forth in Section 2 of this Agreement and the applicable Revision Project
Statement, IXYS shall pay to Samsung the sum set forth in Annex C of each applicable Revision Project Statement (“Mask and Prototyping Fees”). 

Samsung shall issue an invoice for each milestone Mask and Prototyping Fee upon or after the completion of each milestone
under the applicable Mask and Prototyping Services in accordance with the schedule set forth in Annex C of the applicable Revision Project Statement, and IXYS shall pay the invoiced amount to Samsung-designated bank account in US Dollars within ***
days after the receipt of such invoice. 
  

	6.2	 Samsung shall issue an invoice to IXYS with the total amount to be paid for the Products calculated according to Section 1 of Annex B of the
applicable Foundry Project Statement on or after the date that the applicable Products are shipped. IXYS shall pay the total amount properly invoiced for the Products ordered and delivered pursuant to Section 3 of this Agreement. IXYS shall pay
such prices to Samsung-designated bank account in US Dollars within *** days after the receipt of applicable invoice. 

  

	6.3	 All sums stated under this Agreement (including the prices of Products) do not include tax. IXYS shall remit the full sums and shall bear any and
all taxes, including, without limitation, value-added tax and sales tax, incurred from the payment made hereunder. 

  

***Certain confidential information contained in this document, marked with 3 asterisks (***), has been omitted and filed separately with the Securities
and Exchange Commission pursuant to Rule 24b-2 of the Securities Exchange Act of 1934, as amended. 

  
 Page 8 / 24

 Confidential 

 SLSI-201304IA001-1 

 
  

	7	 Inspection and Review 

 IXYS may, upon reasonable advance notice to Samsung, send its employees to visit the applicable Samsung facilities to inspect the fabrication of Products and the performance of any services. Such visit
shall be conducted during Samsung’s normal working hours. While visiting Samsung facilities, IXYS employees shall at all times comply with Samsung’s plant rules and regulations, as well as with reasonable instructions that may be issued by
Samsung’s employee or personnel. 
  

	8	 Business Review Meeting 

 The parties will hold a review meeting on a quarterly basis in order to discuss any business issues and technical issues relating to the subject matter of this Agreement. The parties will also discuss and
negotiate in good faith the availability of an additional year of foundry services provided from Samsung to IXYS. 
  

	9	 Confidential Information 

  

	9.1	Nondisclosure and Nonuse Obligations. Each of the parties, as Recipient, hereby agrees to receive and hold Confidential Information of the Discloser in confidence, and
to protect and safeguard such Confidential Information against unauthorized use or disclosure using at least the same degree of care as Recipient accords to its own confidential information of like importance, but in no case less than reasonable
care. Without limiting the generality of the foregoing, each party, as Recipient, further promises and agrees: 

  

	 	(a)	 except as set forth in subsection (c) below, not to, directly or indirectly, in any way, disclose, make accessible, reveal, report, publish,
disseminate or transfer any such Confidential Information to any unauthorized third party, including parent companies, unless otherwise agreed by the parties; 

 

	 	(b)	 not to use any Confidential Information in any manner whatsoever except in furtherance of the subject matter hereof; 

 

	 	(c)	 to restrict access to Confidential Information to those of its officers, directors, employees and subcontractors who have a legitimate need-to-know
to carry out the purpose of this Agreement and who are obligated to protect such Confidential Information pursuant to terms and conditions no less protective of Discloser than those contained in this Agreement; and 

 

	 	(d)	 not to reproduce or copy Confidential Information except to the extent necessary to further the purpose of this Agreement.

 Furthermore, the existence of any business negotiations, discussions or agreements in
progress between the parties shall be kept confidential and shall not be disclosed without written approval of all the parties, except to their officers, directors, and employees who have a legitimate need-to-know to carry out the purpose of this
Agreement and who are obligated to protect such Confidential Information pursuant to terms and conditions no less protective of Discloser than those contained in this Agreement. 

Recipient’s obligation of confidentiality set forth in this Section 9.1 shall be in force for a period of ten
(10) years after the initial disclosure. 
  

	9.2	 Exclusions from Obligations. The nondisclosure and non-use obligations under this Section 9 shall not

  
 Page 9 / 24

 Confidential 

 SLSI-201304IA001-1 

 

	 	 
apply to, information that the Recipient can evidence: (a) was publicly available at the time of its disclosure to Recipient or became publicly available after its disclosure through no act
or default of Recipient; (b) is rightfully or free of any obligation of confidentiality in the possession of Recipient prior to disclosure to Recipient by Discloser; (c) is received in good faith by Recipient from a third party, free of
any obligation of confidentiality; or (d) is independently developed by Recipient without use of Discloser’s Confidential Information. 

A disclosure by Recipient of Confidential Information of Discloser (a) in response to a valid order by a competent
court or governmental body, (b) in connection with an arbitration hereunder, or (c) as otherwise required by applicable Law shall not be considered to be a breach of this Agreement or a waiver of confidentiality for other purposes;
provided, however, (i) with respect to any disclosure in accordance with clause (b) above shall only be made to persons involved in the arbitration or the arbitrator thereof, and (ii) with respect to any disclosure in accordance with
clause (a) or (c) above, Recipient shall provide prompt prior written notice thereof to Discloser and permit such Discloser to seek measures to maintain the confidentiality of its Confidential Information. 

 

	9.3	 Ownership and Return of Confidential Information. Confidential Information disclosed by Discloser shall remain the property of such Discloser, and,
except as expressly set forth herein, no license or other rights to such Discloser’s Confidential Information is granted or implied hereby. Recipient shall reproduce the symbols, legends or other proprietary notices affixed to Confidential
Information, and shall not, nor permit any third party to, remove, add or modify the same. 

Recipient shall, upon expiration or termination of this Agreement, or upon written request of Discloser, whichever is
earlier, as soon as possible, but not later than twenty (20) days after any notice thereof by Discloser, return (or destroy at Discloser’s option) all copies of such Discloser’s Confidential Information and certify in writing its
compliance with this requirement. 
  

	9.4	 No Reverse Engineering. No party, as Recipient, shall decompile, disassemble, reverse engineer or attempt to reconstruct, identify or discover any
source code, underlying ideas, techniques or algorithms in Confidential Information by any means whatever, except as may be specifically authorized in advance by Discloser in writing. 

 

	9.5	 This Agreement shall not preclude or limit the independent development by or on behalf of any party of any products or systems involving technology
or information of a similar nature to that disclosed hereunder or which compete with products or systems contemplated by such information, provided that any such development is done without use of or reliance upon the other party’s Confidential
Information. 

  

	10	 Indemnity 

  

	10.1	 IXYS shall, at its expense, defend, indemnify and hold harmless Samsung from all Claims, and/or Losses incurred by Samsung as a result of such
Claims or in a settlement that may result from any such Claim, that IXYS Deliverables (unless purchased from Samsung under the APA) actually or allegedly infringe, violate or misappropriate Intellectual Property of a third party, provided that
(a) Samsung promptly notifies IXYS in writing of the Claim, (b) Samsung provides IXYS with all reasonable assistance, information and authority required to perform these duties, and (c) IXYS is permitted to solely direct the defense
and all related settlement negotiations related to the Claim. Further, IXYS agrees to pay any judgment in such suit or proceeding by final judgment of a court of last resort, including reasonable attorneys’ fees, but IXYS shall have no
liability for settlement or costs incurred 

  
 Page 10 / 24

 Confidential 

 SLSI-201304IA001-1 

 

	 	 
without its consent. 

 Notwithstanding
the foregoing, IXYS shall have no indemnity obligation regarding any actual or alleged infringement, violation or misappropriation of any Intellectual Property of any third party to the extent such infringement, violation or misappropriation arises
from the Samsung Deliverables, the manufacturing processes used by Samsung hereunder, or products based on designs acquired from Samsung pursuant to the Transaction Documents. IXYS shall not be obligated to indemnify Samsung in accordance with this
Section 10.1 if (a) any settlement is made by Samsung without IXYS’s prior written consent, or (b) if IXYS is not permitted by Samsung to assume exclusive control of the settlement of the Claim. 

For the purposes of this Section 10 and Section 11, the term “Claim” means any claim, action,
suit or proceeding asserted by any third party whether actual or alleged and whether adjudicated by a competent court of law, tribunal or arbitrator, and the term “Losses” means all damages, losses, costs and expenses of whatever
nature (including legal costs) whether or not reasonably foreseeable by the parties at any time during the term of this Agreement. 
  

	10.2	 Samsung shall, at its expense, defend, indemnify and hold harmless IXYS from all Claims, and/or Losses incurred by IXYS as a result of such Claims
or in a settlement that may result from any such Claim, that Samsung Deliverables contained in the Products, the manufacturing processes used by Samsung hereunder, actually or allegedly infringe on any Intellectual Property of a third party,
provided that Samsung is promptly notified, given the assistance required, and permitted to solely direct the defense. Further, Samsung agrees to pay any judgment in such suit or proceeding by final judgment of a court of last resort, including
reasonable attorneys’ fees, but Samsung shall have no liability for settlement or cost incurred without its consent. 

 Notwithstanding the foregoing, Samsung shall have no indemnity obligation pursuant to this Section 10.2 regarding any actual or alleged infringement of any Intellectual Property of any third party to
the extent such infringement arises from the IXYS Deliverables (including but not limited to the designs, specifications and/or instructions provided by IXYS and Samsung’s compliance with any industrial standard specification) Samsung shall not
be obligated to indemnify in accordance with this Section 10.2 if (a) any settlement is made by IXYS without Samsung’s prior written consent, or (b) if Samsung is not permitted by IXYS to assume exclusive control of the
settlement of the Claim. 
  

	11	 Life Critical Applications 

 Unless otherwise specifically agreed by the parties in writing, IXYS hereby agrees that Products are not authorized for use as, and IXYS shall not integrate, promote, sell or otherwise transfer any
Product to any customer or end user for use as critical components in any device, application or system where it is reasonably foreseeable that failure of the Product(s) as used in such device, application or system would cause death, bodily injury
or catastrophic property damage, such as (a) any medical, life saving or life support device or system, (b) any safety device or system in automotive application and mechanism (including but not limited to automotive brake or airbag
systems), (c) any nuclear facilities, (d) any air traffic control device, application or system, or (e) any weapons device, application or system (the “Life Critical Applications”). Notwithstanding anything contrary
to the limitation of liability of IXYS as set forth in this Agreement or APA, IXYS shall, at its expense, defend, indemnify and hold harmless Samsung from all Claims arising from using the Products in the Life Critical Applications, and/or Losses
incurred or arising out of or in connection with such Claims. 

  
 Page 11 / 24

 Confidential 

 SLSI-201304IA001-1 

 
  

	12	 Limited Warranty, Limitation of Liability & Disclaimer 

 

	12.1	 Samsung warrants that the (a) Mask and Prototyping Services and manufacture of the Products hereunder shall be performed in a good,
professional and workmanlike manner in accordance with industry standards; (b) Products shall conform to the applicable Product Specification; (c) Products shall be free from material defects arising from the fabrication process. The
foregoing warranties shall continue for a period of *** commencing on the date on which applicable Products have been delivered hereunder. For clarity, the foregoing warranties shall not apply to the extent caused by (1) IXYS’s or a third
party’s abuse, misuse, negligence, mishandling or improper modification, or (2) IXYS Deliverables and the designs, specifications, or instructions provided by IXYS. For further clarity, the foregoing warranties shall not apply to
Engineering Samples or any unauthorized use of Products for Life Critical Applications. In the event of a breach of warranty set forth herein, as IXYS’s sole and exclusive remedy, Samsung shall replace the defective Products or, upon IXYS’
request, discuss in good faith a refund the full Product Prices for such defective Products. 

  

	12.2	 Except as provided in Section 12.1 above, all Samsung Deliverables, Products, and Project Results provided to IXYS shall be provided
“AS IS,” WITHOUT WARRANTY OF ANY KIND. EXCEPT AS PROVIDED IN SECTION 12.1 ABOVE, SAMSUNG MAKES NO OTHER REPRESENTATIONS OR WARRANTIES INCLUDING, WITHOUT LIMITATION, THE WARRANTIES OF MERCHANTABILITY, FITNESS FOR PARTICULAR PURPOSE AND
NON-INFRINGEMENT. 

  

	12.3	 EXCEPT FOR THE DAMAGES ARISING OUT OF (A) EITHER PARTY’S WILLFUL BREACH OF SECTIONS 2 OR 3 OR (B) EITHER PARTY’S OBLIGATIONS
UNDER OR BREACH OF SECTIONS 5, 9, 10 AND/OR 11, NEITHER PARTY SHALL BE LIABLE FOR ANY INDIRECT, SPECIAL, INCIDENTAL OR CONSEQUENTIAL DAMAGES RESULTING FROM ITS PERFORMANCE OR FAILURE TO PERFORM UNDER THIS AGREEMENT, WHETHER DUE TO A BREACH OF
CONTRACT OR BREACH OF WARRANTY. EXCEPT WITH RESPECT TO (A) EITHER PARTY’S WILLFUL BREACH OF SECTIONS 2 OR 3; AND (B) EITHER PARTY’S OBLIGATIONS UNDER OR BREACH OF SECTIONS 5, 6, 9 AND 11, EACH PARTY’S TOTAL LIABILITY UNDER
THIS AGREEMENT SHALL NOT EXCEED *** PERCENT OF ALL PAYMENTS RECEIVED BY SAMSUNG FROM IXYS UNDER THIS AGREEMENT FOR THE APPLICABLE PRODUCT(S) DURING THE PREVIOUS *** MONTHS PRIOR TO THE CLAIM BEING BROUGHT AGAINST SUCH LIABLE PARTY.

  

	13	 Term and Termination 

  

	13.1	 This Agreement shall remain in effect from the Effective Date until *** months after the Effective Date (the “Initial Term”),
unless terminated earlier in accordance with Section 13.2. At least *** years prior to the expiration of the Initial Term, the parties will discuss and negotiate in good faith the availability of an additional year of foundry services provided
from Samsung to IXYS. 

  
 ***Certain confidential
information contained in this document, marked with 3 asterisks (***), has been omitted and filed separately with the Securities and Exchange Commission pursuant to Rule 24b-2 of the Securities Exchange Act of 1934, as amended. 

  
 Page 12 / 24

 Confidential 

 SLSI-201304IA001-1 

 

	13.2	 Notwithstanding the above, either party shall have the right to terminate this Agreement (together with all Foundry Project Statements and all
Revision Project Statements) immediately if: 

  

	 	(a)	 the other party files a petition in bankruptcy, undergoes a reorganization pursuant to a petition in bankruptcy, is adjudicated a bankrupt, becomes
insolvent, becomes dissolved or liquidated, files a petition for dissolution or liquidation, makes an assignment for benefit of creditors, or has a receiver appointed for its business; 

 

	 	(b)	 the other party is subject to property attachment or court injunction or court order which has a substantial negative effect on its ability to
fulfill its obligations under this Agreement; or 

  

	 	(c)	 a competent governmental authority cancels or suspends the business license of the other party or takes similar actions against such other party.

  

	 	(d)	 the other party materially breaches its confidentiality obligations in this Agreement and does not cure or agree with the non-breaching party upon a
written plan to cure such breach within thirty (30) days after receipt of notice of such breach from the non-breaching party. 

  

	 	(e)	 the other party breaches its payment obligations in this Agreement and does not cure or agree with the non-breaching party upon a written plan to
cure such breach within fifteen (15) days after receipt of notice of such breach from the non-breaching party. 

  

	13.3	 Sections 1, 3 (for outstanding Purchase Orders and Short Term Forecasts only), 5, 6, 9.1 (but only for the period set forth therein), 9.2, 9.3, 9.4,
9.5, 10, 11, 12, 13.3, 14 and 15 (except 15.6) shall survive any termination or expiration of this Agreement. 

  

	14	 Governing Law / Dispute Resolution 

  

	14.1	 Governing Law. This Agreement (and any claims or disputes arising out of or related hereto or to the transactions contemplated hereby or to the
inducement of any party to enter herein, whether for breach of contract, tortious conduct or otherwise and whether predicated on common law, statute or otherwise) shall in all respects be governed by, and construed in accordance with, the laws of
the New York of the United States of America , including all matters of construction, validity and performance, in each case without reference to any conflict of law rules that might lead to the application of the laws of any other jurisdiction.

  

	14.2	 Dispute Resolution. All disputes arising out of or in connection with this Agreement shall be finally settled under the Rules of Arbitration of the
International Chamber of Commerce by one or more arbitrators appointed in accordance with the said Rules. The place of arbitration shall be Singapore. The language of the arbitral proceedings shall be English. Judgment upon any award(s) rendered by
the arbitrator(s) may be entered in any court having jurisdiction thereof. The arbitrator(s) are authorized to include in the award an allocation to any party of such costs and expenses, including attorneys’ fees, as the arbitrator shall deem
reasonable. Nothing in this Agreement shall prevent either party from seeking provisional measures from any court of competent jurisdiction to enforce its intellectual property rights, and any such request shall not be deemed incompatible with the
agreement to arbitrate or a waiver of the right to arbitrate. The parties undertake to keep confidential all awards in their arbitration, together with all materials in the proceedings created for the purpose of the arbitration and all other
documents produced by another party in the proceedings not otherwise in the public domain, save and to the extent that disclosure may be required of a party by legal duty, to protect or pursue a legal right or to enforce or

  
 Page 13 / 24

 Confidential 

 SLSI-201304IA001-1 

 

	 	 
challenge an award in legal proceedings before a court or other judicial authority. 

  

	15	 General 

  

	15.1	 Assignment. No party may assign its right or delegate its obligations under this Agreement without the written consent from the other party, except
that IXYS may assign its rights and obligations without Samsung’s consent to a successor of all or substantially all of the assets of IXYS related to the Business. Any purported assignment or delegation without such consent shall have no force
or effect and any attempt to do so without such consent shall be void. 

  

	15.2	 Independent Contractor. No party is authorized to act for or on the behalf of the other party under this Agreement. Without limiting the generality
of the foregoing, each party is an independent contractor, and no principal/agent or partnership relationship is created among the parties by this Agreement. 

 

	15.3	 No Third-Party Beneficiaries. This Agreement shall inure to the benefit of and be binding upon the parties hereto and their respective successors
and assigns. Nothing in this Agreement expressed or implied, is intended to or shall confer on any person or entity other than the parties hereto or their respective successors and assigns, any rights, remedies or Liabilities under or by reason of
this Agreement. 

  

	15.4	 No Waiver. No failure or delay by any party to enforce or take advantage of any provision or right under this Agreement shall constitute a
subsequent waiver of that provision or right, nor shall it be deemed to be a waiver of any other terms and conditions of this Agreement. 

  

	15.5	 Force Majeure. Neither party to this Agreement shall be liable for its failure or delay to perform any of its obligations hereunder during any
period in which such performance is prevented by any cause beyond its reasonable control, including, without limitation, act of God, acts of civil or military authority, fires, epidemics, floods, earthquakes, riots, war, and governmental control
(each, a “Force Majeure Event”). In the event of any such Force Majeure Event the date of delivery or performance hereunder shall be extended by a period equal to the time lost by reason of such Force Majeure Event, provided that
the affected party promptly notifies the other party of the occurrence of the Force Majeure Event and takes all reasonable steps necessary to resume performance of its obligations so interfered with. 

 

	15.6	 Disaster Recovery Plan.  Samsung agrees to prepare a written disaster recovery plan describing the measures anticipated to be taken by
Samsung to ensure the continued supply of Products to IXYS pursuant to the requirements of this Agreement in the event of any Force Majeure Event (“Disaster Recovery Plan”). 

 

	15.7	 Export. Each party shall comply with all then-current applicable laws, regulations and other legal requirements in its performance in connection
with this Agreement, including, without limitation, all applicable export control laws, rules and regulations of the United States, the Republic of Korea, and any other relevant countries. 

 

	15.8	 Notice. All notices or communications to be given under this Agreement shall be in writing and shall be deemed delivered upon hand delivery or
acknowledgment of facsimile, by international overnight courier, or by certified, registered or first class mail, addressed to the parties at their addresses set forth above or below. Unless the sending party can reasonably prove by contemporaneous
written evidence that it was received earlier (in which case, the applicable notice shall be deemed given as of such earlier 

  
 Page 14 / 24

 Confidential 

 SLSI-201304IA001-1 

 

	 	 
date), a notice given under this Agreement is deemed given: 

  

	 	(a)	If delivered personally, when left at the address, and addressed, as set forth in this Section; 

 

	 	(b)	If sent by overnight courier, two (2) business days after posting; 

  

	 	(c)	If sent by domestic post, except airmail, two (2) business days after posting; 

 

	 	(d)	If sent by airmail, ten (10) business days after posting; or 

  

	 	(e)	If sent by facsimile, when confirmation of its transmission has been recorded by the sender’s facsimile machine. 

Any notice to be sent to the parties shall be sent as follows: 

 

	 	(1)	To Samsung    : 

  

					
		  	Name:	  	Samsung Electronics
			
		  	Address:	  	San #24, Nonseo-Dong, Giheung-Gu, Yongin-City, Gyeonggi-Do,
			
		  		  	449-711 Korea
			
		  	Attention:	  	Kyeyoung Cho, Seungjin Yang
			
		  	Telephone:	  	+82-31-209-5071, +82-31-209-8385
			
		  	Facsimile:	  	
		  	e-mail:	  	kyeyoung.cho@samsung.com, sj74.yang@samsung.com

  

	 	(2)	To IXYS : 

  

					
		  	Name:	  	IXYS Intl Limited
			
		  		  	c/o IXYS Corporation
			
		  	Address:	  	1590 Buckeye Drive, Milpitas, CA 95035
			
		  	Attention:	  	Uzi Sasson
			
		  	Telephone:	  	+1.408.457.9000
		  	Facsimile:	  	+1.408.416.0224
		  	e-mail:	  	u.sasson@ixys.net

  

	15.9	 Severability. In the event that any provision of this Agreement becomes or is declared by a court of competent jurisdiction to be illegal,
unenforceable or void, this Agreement shall continue in full force and effect without said provision. The captions of the sections in this Agreement are intended for convenience only, and shall not be interpretive of the content of the accompanying
section. 

  

	15.10	 Modification. The terms and conditions of this Agreement shall not be modified, or amended except in

  
 Page 15 / 24

 Confidential 

 SLSI-201304IA001-1 

 

	 	 
writing indicating a modification thereof, and signed by the authorized representatives of both parties. 

 

	15.11	 Publicity. Without procuring the other party’s prior written consent, neither party shall issue any public announcement with respect to the
subject matter hereof. 

  

	15.12	 Counterparts.  This Agreement may be signed in any number of counterparts, each of which shall be an original, with the same effect as if
the signatures thereto and hereto were upon the same instrument. 

  

	15.13	 Entire Agreement.    This Agreement, including the applicable Foundry Project Statements and the applicable Revision Project
Statements (which are incorporated herein by reference), constitutes the entire agreement between the parties as to the subject matter hereof, and supersedes and replaces all prior or contemporaneous agreements, written or oral, regarding such
subject matter, and shall take precedence over any additional or conflicting terms which may be contained in either party’s purchase orders or order acknowledgment forms. 

 

			
	Attachments:	  	Attachment1 – Foundry Project Statement
		
		  	Attachment 2 – Revision Project Statement

 [Signature Blocks on the Next Page] 

  
 Page 16 / 24

 Confidential 

 SLSI-201304IA001-1 

 
 In witness hereof, the parties have executed this Agreement
by their duly authorized representatives: 
  

									
	Samsung Electronics Co., Ltd.	  		  	IXYS Intl Limited
					
	 By:
  
	  	 /s/ Byunghoon Suh
  
	  		  	 By:
  
	  	 /s/ Uzi Sasson
  

	 Name:
  
	  	 Byunghoon Suh
  
	  		  	 Name:
  
	  	 Uzi Sasson
  

	 Date:
  
	  	 June 27, 2013
  
	  		  	 Date:
  
	  	 June 27, 2013
  

  
 Page 17 / 24

 Confidential 

 SLSI-201304IA001-1 

 
 Attachment 1 – Foundry Project Statement 

Foundry Project Statement for Product [A] 
 This Foundry Project Statement (“Foundry Project Statement”) is entered into as of [Date] (“Foundry Project Statement Effective Date”) by and between Samsung Electronics
Co., Ltd. (“Samsung”) and IXYS Intl Limited (“IXYS”). 
 WHEREAS, the parties have entered
into a Foundry Services Agreement (the “Agreement”) with an Effective Date of [Date], and now desire to define Product Prices and other terms and conditions for the Products specified in Annex A. Product List of this Foundry Project
Statement, pursuant to the terms and conditions contained in the Agreement. 
 NOW, THEREFORE, in consideration of the exchange
of obligations herein, the parties hereby agree as follows: 
 1. All capitalized terms not defined herein shall have the
meanings ascribed to them in the Agreement. 
 2. Once executed by the parties, this Foundry Project Statement shall become an
integral part of the Agreement and the terms of the Agreement shall be fully incorporated herein, provided that, in the event of a conflict between this Foundry Project Statement and the Agreement, the terms of this Foundry Project Statement shall
prevail. 
 3. The parties agree to incorporate the following into this Foundry Project Statement: 

Annex A. Product List 
 Annex B. Financial Terms and Other Special Terms 
 4. This Foundry Project
Statement shall become effective as of the Foundry Project Statement Effective Date and remain in effect for the Initial Term. Upon expiration of this Foundry Project Statement, the parties may discuss extending the term for an additional one year
period. 
 In Witness Whereof, the parties have executed this Foundry Project Statement by their duly authorized
representatives: 
  

									
	Samsung Electronics Co., Ltd.	  		  	IXYS Intl Limited.
					
	 By:
  
	  	  
	  		  	 By:
  
	  	  

	 Name:
  
	  	  
	  		  	 Name:
  
	  	  

	 Date:
  
	  	  
	  		  	 Date:
  
	  	  

  
 Page 18 / 24

 Confidential 

 SLSI-201304IA001-1 

 
 Annex A: Product List 

*** 
  
 ***Certain confidential information contained in this document, marked with 3 asterisks (***), has been omitted and filed separately with the Securities and Exchange Commission pursuant to Rule 24b-2 of
the Securities Exchange Act of 1934, as amended. 

  
 Page 19 / 24

 Confidential 

 SLSI-201304IA001-1 

 
 Annex B. Financial Terms and Other Special Terms 

 
 1. Product Price 

The Product Price (***) as of the Foundry Project Statement Effective Date will be as follows; 

 

									
	Calendar Year	 	Year 1	 	Year 2	 	Year 3	 	Year 4 and onwards
	
Product Price (***)    
	 	***	 	***	 	***	 	***

 The Product Price per a unit as of the Foundry Project Statement Effective Date will be as follows;

  

													
	 Master

Code
  
	  	        
Material Code        	  	  

Package_Test    
Cost    

 
	  	Final Chip
Price
	  	  	  	  Year 1  	  	  Year 2  	  	  Year 3    	  	  Year 4    

	  	  	Pac. Type  	  	  	  	  
	***	  	***	  	  ***	  	***    	  	***	  	***	  	***

 ø Above chip price may be varied based on the back-end
process costs. 
  

					
	 *** Price:
	  		  	
		  	(KRW/second)  	  	
	 ***
	  	*** 	  	

   * for the year of 2013 

					
	   *** Price:
	  	(KRW/CHIP)  	  	
	 ***
	  	*** 	  	
	   * for the year of 2013
	  	

  
 Note: The above prices are to be
reference prices. 
 Both parties shall mutually agree to the Product Price in each Purchase Order, considering various factors
collectively such as die size of Product, fabrication process technology, volume projection, the status of market pricing conditions, and other Samsung’s services, etc. 
 2. Volume Production Commencing Date 
 Volume Production Commencing Date shall be
effective as of the [            ] 
  
 ***Certain confidential information contained in this document, marked with 3 asterisks (***), has been omitted and filed separately with the Securities and Exchange Commission pursuant to Rule 24b-2 of
the Securities Exchange Act of 1934, as amended. 

  
 Page 20 / 24

 Confidential 

 SLSI-201304IA001-1 

 
 Attachment 2 – Revision Project Statement 

Revision Project Statement for Product [Product Name] 
 This Revision Project Statement (“Revision Project Statement”) is entered into as of [Date] (“Revision Project Statement Effective Date”) by and between Samsung
Electronics Co., Ltd. (“Samsung”) and IXYS Intl Limited (“IXYS”). 
 WHEREAS, the parties have
entered into a Foundry Services Agreement (the “Agreement”) with an Effective Date of [Date], and now desire to define details of Mask and Prototyping Services and other terms and conditions, if any, for a Product specified in Annex
A. Product and Revision Specification of this Revision Project Statement, pursuant to the terms and conditions contained in the Agreement; 
 NOW, THEREFORE, in consideration of the exchange of obligations herein, the parties hereby agree as follows: 
 1. All capitalized terms not defined herein shall have the meanings ascribed to them in the Agreement. 
 2. Once executed by the parties, this Revision Project Statement shall become an integral part of the Agreement and the terms of the Agreement shall be fully incorporated herein, provided that, in the
event of a conflict between this Revision Project Statement and the Agreement, the terms of this Revision Project Statement shall prevail. 
 3. The parties agree to incorporate the following into this Revision Project Statement: 
 Annex A. Product and Revision Specification 
 Annex B. SOW

 Annex C. Financial Terms and Other Special Terms 

4. This Revision Project Statement shall become effective as of the Revision Project Statement Effective Date and remain in effect for
the Initial Term. Upon expiration of this Revision Project Statement, the parties may discuss extending the term for an additional one year period. 
 In Witness Whereof, the parties have executed this Revision Project Statement by their duly authorized representatives: 
  

									
	Samsung Electronics Co., Ltd.	  		  	IXYS Intl Limited.
					
	 By:
  
	  	  
	  		  	 By:
  
	  	  

	 Name:
  
	  	  
	  		  	 Name:
  
	  	  

	 Date:
  
	  	  
	  		  	 Date:
  
	  	  

  
 Page 21 / 24

 Confidential 

 SLSI-201304IA001-1 

 
 Annex A: Product and Revision Specification 

Product : 

Process : 

Revision Specification or Description. 

  
 Page 22 / 24

 Confidential 

 SLSI-201304IA001-1 

 
 Annex B: SOW 

1. IXYS Deliverables include the following: 
 [XX] 
 2. Samsung Deliverables include the following: 

[XX] 
 3.
Project Schedule/Project Results 
  

					
	Product	  	Work	  	Project Results      
  
	 	 	 
	 	  	 	  	 
	 	 	 
	 	  	 	  	 
	 	 	 
	 	  	 	  	 
	 	 	 
	 	  	 	  	 
	 	 	 
	 	  	 	  	 
	 	 	 
	 	  	 	  	 
	 	 	 
	 	  	 	  	 
	 	 	 
	 	  	 	  	 
	 	 	 
	 	  	 	  	 
	 	 	 
	 	  	 	  	 
	 	  	 	  	 
	 	 	 
	 	  	 	  	 
	 	  	 	  	 

  
 Page 23 / 24

 Confidential 

 SLSI-201304IA001-1 

 
 Annex C. Financial Terms and Other Special Terms 

1. Mask and Prototyping Fees 
 IXYS shall pay to Samsung the following Mask and Prototyping Fees for Mask and Prototyping Services performed under the Revision Project Statement and in accordance with the provisions of the Agreement:

  

			
	Milestone	  	Mask and Prototyping
Fee
	Milestone 1. ***	  	 *** of the total Mask and Prototyping Fees

	Milestone 2. ***	  	 *** of the total Mask and Prototyping Fees

	Milestone 3. ***	  	 *** of the total Mask and Prototyping Fees

	Total Mask and Prototyping Fees	  	 

  
 ***Certain confidential
information contained in this document, marked with 3 asterisks (***), has been omitted and filed separately with the Securities and Exchange Commission pursuant to Rule 24b-2 of the Securities Exchange Act of 1934, as amended. 

Page 24 / 24 

ConfidentialEX-10.3

 Exhibit 10.3 
 SLSI-201304IA001-2 
 TRANSITION SERVICES AGREEMENT 

This TRANSITION SERVICES AGREEMENT (this “Agreement”) is made and entered into as of 27th day of June, 2013 (the “Effective Date”) by and
between Samsung Electronics Co., Ltd., a company organized under the laws of the Republic of Korea (the “Seller”), and IXYS Intl Limited, a corporation incorporated under the laws of the Cayman Islands (the
“Purchaser”). 
 RECITALS 

WHEREAS, the Purchaser and the Seller have entered into that certain Asset Purchase
Agreement, dated as of May 25th, 2013 (the “Purchase Agreement”, Seller document number SLSI-201304IA001), pursuant to which the Seller has sold and transferred certain assets related to the Business to the Purchaser and, in
connection therewith, the Seller and the Purchaser entered into (i) that certain Foundry Services Agreement, dated as of 27th day of June, 2013 (the “Foundry Services Agreement”), and (ii) that certain Product License
Agreement, dated as of 27th day of June, 2013 (the
“Product License Agreement”); 
 WHEREAS, in further
consideration of the Purchase Agreement, the Purchaser will require the Seller’s assistance with respect to certain operations of the Business following the Closing Date, as more fully set forth herein. 

NOW, THEREFORE, in consideration of the mutual promises of the
parties, and of good and valuable consideration, the receipt of which is hereby acknowledged, it is agreed by and between the parties as follows: 
 1.        DEFINITIONS.  The defined terms used in this Agreement shall have the meanings set forth in this
Section 1 or in the text of the Agreement. Capitalized terms used herein and not otherwise defined in the Agreement have the meanings given to such terms in the Purchase Agreement or the Product License Agreement, as applicable. 

1.1      “Pass-Through Expenses” shall mean the reasonable,
documented, out-of-pocket expenses actually incurred by the Seller or its Affiliates in performing the Services under this Agreement, provided that such category of out-of-pocket expenses has been specified in the Services Exhibit as chargeable to
such Services. “Pass-Through Expenses” shall not include any overhead costs, Seller profits or other mark-ups. 
 1.2      “Seller Expense Table” shall mean the Seller’s payroll, cost, expense or travel cost for the performance of the Services. 

1.3      “Services” shall mean the set of tasks that the Seller
will perform for the Purchaser as specified in the Services Exhibit. 

1.4      “Services Exhibit” shall mean Exhibit A attached hereto,
as it may be amended from time to time by mutual written agreement of the parties. 

1.5      “Service Period” shall mean the duration of a Service as
set forth in the Services Exhibit. 
 ***Certain confidential information contained in this document, marked with 3 asterisks (***), has been
omitted and filed separately with the Securities and Exchange Commission pursuant to Rule 24b-2 of the Securities Exchange Act of 1934, as amended. 

 SLSI-201304IA001-2 

 

	2.	TRANSITION SERVICES. 

 2.1      Services.  During the Term of this Agreement, and except for the manufacturing services provided pursuant to the Foundry Agreement, the Seller shall
provide, and as necessary shall cause its Affiliates to provide, to the Purchaser the Services specified in the Services Exhibit, for the periods set forth therein. Except as otherwise expressly provided in this Agreement (including in the Services
Exhibit), the Seller will be responsible for providing the equipment, Seller Personnel (as defined below), and other resources required for the Seller’s performance of the Services. In the event of any conflict between the terms of the Services
Exhibit and this Agreement, the terms of the Services Exhibit shall prevail. 

2.2      Modification of Services.  Without limiting the foregoing, the
parties acknowledge that the scope or characteristics of the Services may change during the term of this Agreement as the Purchaser completes its transition from dependence on the Seller’s Services. If the Purchaser reasonably believes that it
is necessary to supplement, modify, substitute, reduce or otherwise alter the Services specified in the Services Exhibit, including without limitation changes that may affect the content, scope, or service levels (“Changes”), it
shall make a written request for such Changes to the Seller, and the parties will discuss in good faith the implementation of any such Changes and any changes to the terms of the Services Exhibit to effect such Change. The Seller may not make
Changes until the parties have mutually agreed upon such Changes in writing. 

2.3      Additional Services.  From time to time after the Closing Date,
the parties may identify additional services to be provided to the Purchaser in accordance with the terms of this Agreement (the “Additional Services”). The parties will discuss in good faith any Additional Services, and if the
Parties agree to such Additional Services, the parties shall amend the Services Exhibit to add each Additional Service setting forth a description of the Additional Service, the time period during which the Additional Service will be provided, the
applicable service levels, the charge, if any, for the Additional Service and any other terms applicable thereto. 
 2.4      Service Levels; Standards of Performance.  The Seller will use commercially reasonable efforts to provide the Services in accordance with the
specifications or other standards set forth in the Services Exhibit, and otherwise in the same or substantially similar manner as the equivalent services were provided by Seller or its Affiliates with respect to the Business immediately prior to the
Closing. The Seller will comply with all laws and regulations applicable to Seller with respect to its performance of the Services, and will obtain all necessary permits and licenses applicable to Seller with respect to its performance of the
Services. The Seller shall cause all Seller Personnel (as defined below) to comply with the standards set forth in this Section 2.4. 
 2.5      Expenses.  Except as may be expressly set forth in the Services Exhibit or otherwise provided in this Agreement, each party will bear its own
expenses in connection with its obligations under this Agreement. 

2.6      Subcontractors.  The Services may be provided in whole or in part
by Affiliates of the Seller or by third-party subcontractors selected by the Seller, subject to the prior written 

 SLSI-201304IA001-2 

 

 
approval of the Purchaser, which approval shall not be unreasonably withheld. Any such delegation or appointment shall not release the Seller from any of its obligations under this Agreement. The
Seller shall be responsible for the work and activities of each of its Affiliates and subcontractors, including compliance with the terms of this Agreement. The Seller shall be responsible for all payments to its subcontractors, unless the Services
Exhibit provides otherwise or the Purchaser agrees in writing to pay the subcontractor directly for the applicable Service. 
 2.7      Service Provider Contracts.  To the extent that at the end of the Term of this Agreement the Purchaser will also require an agreement with any
third-party service provider used by the Seller in connection with the Services as of the Closing Date, the Seller agrees to use commercially reasonable efforts to assist the Purchaser to obtain terms and conditions, including pricing terms,
substantially similar to those received from such service providers by the Seller prior to the Closing Date. 
  

	3.	MANAGEMENT. 

 3.1      Each party will have day-to-day management control over its provision and/or receipt of the Services. To administer its provision and/or receipt and use of
the Services, each party will retain a Services Coordinator who shall (i) have overall responsibility during the term of this Agreement for managing and coordinating the delivery of the Services; (ii) be authorized to act for and on behalf
of the appointing party with respect to all matters relating to this Agreement, and (iii) be the primary contact with the other party’s Services Coordinator. The Services Coordinators from each party, or their designees for specific
Services, shall meet regularly on a mutually agreed upon schedule, and shall cooperate and consult in relation to the Services in their reasonable judgment. Each party may, at its discretion, and upon written notice to the other party, designate
other or additional individuals to serve in these capacities during the term of this Agreement. 
  

	4.	PERSONNEL. 

 4.1      Personnel.  The Seller will make available such Seller employees and agents as are required to provide each of the Services (the “Seller
Personnel”). The parties may agree in the Services Exhibit on any specific employees that are required to be utilized in providing the applicable Services (the “Key Employees”). 

4.2      Right to Designate and Change Seller Personnel.  The Seller shall
be entitled to remove or replace any Seller Personnel at any time; provided, however, the Seller will use commercially reasonable efforts to limit the disruption to the Purchaser as a result of such removal or replacement. 

4.3      Responsibility for Seller Personnel.  Seller Personnel will be
under the direction, control and supervision of the Seller, and the Seller will have the sole right to exercise all authority with respect to the employment, termination, assignment, and compensation of such Seller Personnel under the applicable
Law. The Seller (or its Affiliates) will be solely responsible for payment of (i) all income, disability, withholding, and other employment taxes and (ii) all medical benefit premiums, vacation pay, sick pay, or other fringe benefits for
any employees, agents, or contractors of the Seller who perform the Services. 

 SLSI-201304IA001-2 

 

	5.	FEES AND PAYMENT. 

5.1      Service Charges.  Except as otherwise stipulated in the Services
Exhibit, the Purchaser shall pay an amount equal to payroll for Service time of Seller Personnel in accordance with this Section 5, pursuant to the Seller Expense Table set forth in the Service Exhibit. All payment under this Agreement
(including the Pass-Through Expenses) do not include tax. 

5.2      Expenses.  The Purchaser shall pay or reimburse the Seller for
Pass-Through Expenses reasonably calculated and invoiced to the Purchaser in accordance with this Section 5. 
 5.3      Payment; Invoices.  Amounts payable, if any, hereunder will be billed and paid in U.S. dollars. Within thirty (30) days after the end of each
calendar month, the Seller will submit one (1) invoice to the Purchaser for any amounts payable by the Purchaser hereunder for the previous month; itemizing the Pass-Through Expenses payable and to which Service each is applicable to. Each
invoice will be accompanied by such supporting documentation as is necessary for the Purchaser to verify the Pass-Through Expenses charged during the applicable period, or otherwise as the Purchaser reasonably requests. The Purchaser will pay all
amounts due pursuant to this Agreement within forty-five (45) days after the receipt of the applicable invoice from the Seller unless a different period is specified in the Services Exhibit. 

5.4      Audit.  The Purchaser shall have the right, upon reasonable
written notice to the Seller and at the Purchaser’s cost, to have an independent third party reasonably acceptable to the Seller to audit any Service fees and any Pass-Through Expenses charged by the Seller. Such audit shall be conducted no
more than once every calendar half-year and only during normal business hours. If such audit reveals an overcharge by the Seller, then the Seller shall promptly reimburse the Purchaser. If the audit reveals an overcharge of greater than five percent
(5%) of the aggregate Service fees and Pass-Through Expenses for any given calendar quarter, then the reasonable costs and expenses incurred in connection with such audit shall be borne by the Seller. 

 

	6.	CONFIDENTIALITY. 

 6.1      The confidentiality provisions set forth in Section 6.4 of the Purchase Agreement shall apply to all proprietary, secret or confidential information
disclosed by either party under this Agreement. 
  

	7.	REPRESENTATIONS AND WARRANTIES 

7.1      Consents.  The Seller represents and warrants that it has
obtained all consents, approvals, or agreements from any third party (each, a “Consent”) required for the Seller to provide the Services pursuant to this Agreement (or to use any equipment or software owned by or leased or licensed
to the Seller or any of its Affiliates in connection with the provision of such Services) 

7.2      Performance.  Without limiting any other provision in this
Agreement, the Seller represents and warrants that the Seller will perform the Services in a timely and professional manner and in accordance with industry standards for services of the type performed hereunder. 

 SLSI-201304IA001-2 

 

	8.	TERM AND TERMINATION. 

8.1      Term.  The term of this Agreement shall commence on the Closing
Date and, unless extended by written agreement of the parties pursuant to Section 8.2 or terminated earlier pursuant to Section 8.3, shall continue until the termination or expiration of all Services pursuant to the Services Exhibit, no
longer than *** months after Closing Date (the “Term”). 

8.2      Term Extensions.    This Agreement may be extended in
writing by mutual agreement of the parties either in whole or with respect to one or more of the Services. 

8.3      Termination. 

(a)      The Purchaser may terminate any Service, in whole or in part with respect
to such Service: (i) for any reason or no reason, upon at least thirty (30) days’ prior written notice to the Seller of such termination (unless a longer notice period is specified in the Services Exhibit or is required under a
third-person agreement pursuant to which such Service is provided); or (ii) at any time, upon prior written notice to the Seller, if the Seller has failed to perform any of its material obligations under this Agreement with respect to such
Service and such failure is still occurring thirty (30) days after receipt by the Seller of a written notice of such failure from the Purchaser. 
 (b)      The Seller may terminate any Service, in whole or in part with respect to such Service at any time, upon prior written notice to the Purchaser, if the
Purchaser has materially failed to perform any of its material obligations under this Agreement with respect to such Service and such failure is still occurring thirty (30) days after receipt by the Purchaser of a written notice of such failure
from the Seller or the applicable Affiliate providing Services. 

(c)      If either party becomes aware of a change in applicable Law or other
circumstance that would result in the continued performance of any Service being a violation of any applicable Law, such party will notify the other party in writing as soon as reasonably practicable, and the parties shall cooperate in good faith to
make reasonable modifications to such Service or find reasonable alternative means by which such Service can continue to be provided in compliance with applicable Laws. If the parties are unable to find a mutually acceptable alternative means of
providing such Service that complies with applicable Law within thirty (30) days of starting such discussions, either party may terminate such Service immediately upon written notice to the other party. 

(d)      Any Service may be terminated at any time upon mutual agreement of the
parties. 
 8.4      Effect of Termination. 

(a)      Immediately following the expiration or termination of this Agreement, the
Seller shall cease, or cause its Affiliates or subcontractors to cease, providing the Services. Upon termination of any Service in accordance with this Agreement, (i) the Seller shall have no further obligation to provide such terminated
Service, and (ii) the Purchaser shall have no obligation to pay any additional Pass-Through Expenses relating to any such Service that would be incurred after the effective date of such termination; provided, however, that, the Purchaser

  
 ***Certain
confidential information contained in this document, marked with 3 asterisks (***), has been omitted and filed separately with the Securities and Exchange Commission pursuant to Rule 24b-2 of the Securities Exchange Act of 1934, as amended

 SLSI-201304IA001-2 

 

 
shall remain obligated to pay to the Seller any Pass-Through Expenses owed and payable with respect to any component of such terminated Service that was provided prior to the effective date of
such termination. In connection with the termination of any Service, the provisions of this Agreement not relating solely to such terminated Service shall survive any such termination. 

8.5      Upon the termination or expiration of any Service with respect to which a
party or an Affiliate thereof holds books, records, files, databases, confidential or proprietary information or computer software or hardware (including, without limitation, current and archived copies of computer files) owned or leased by the
other party or an Affiliate thereof and used in connection with the provision of such Service (the “Materials”), subject to the terms of Section 6.1, such party will return, or destroy and certify the destruction of, all such
Materials promptly upon the termination or expiration of the applicable Service, but not later than thirty (30) days after such termination or expiration. 
 8.6      Survival.  Sections 1, 5.3, 6, 8 and 10 of this Agreement shall survive any expiration or termination of this Agreement. 

 

	9.	LIMITATION ON LIABILITY; DISCLAIMER OF WARRANTIES

 9.1      Limitation on
Liability.    NOTWITHSTANDING ANYTHING TO THE CONTRARY IN THIS AGREEMENT, IN NO EVENT SHALL SELLER OR ANY SELLER AFFILIATE BE LIABLE (A) FOR ANY SPECIAL, INCIDENTAL, INDIRECT OR CONSEQUENTIAL DAMAGES, INCLUDING LOSS OF
PROFITS OR BUSINESS OR LOSS OF ANTICIPATED SAVINGS, ARISING FROM OR RELATING TO ANY ACT OR OMISSION UNDER THIS AGREEMENT, AND (B) TO PURCHASER OR ITS AFFILIATES UNDER THIS AGREEMENT FOR ANY AMOUNT IN EXCESS OF THE AGGREGATE SERVICE CHARGES PAID
BY PURCHASER UNDER THIS AGREEMENT. 
 9.2      No Express or Implied
Warranties.  Purchaser acknowledges and agrees that, except to the extent expressly set forth in this Agreement, NEITHER SELLER NOR ANY AFFILIATE OF SELLER IS MAKING ANY REPRESENTATIONS OR WARRANTIES WHATSOEVER, EXPRESS OR IMPLIED,
WITH RESPECT TO THE SERVICES OR ANY OTHER MATTER RELATING TO THIS AGREEMENT, AND SELLER AND EACH AFFILIATE OF SELLER HEREBY EXPRESSLY DISCLAIMS ANY AND ALL WARRANTIES (INCLUDING, WITHOUT LIMITATION, MERCHANTABILITY AND FITNESS FOR A PARTICULAR
PURPOSE) IN CONNECTION THEREWITH. 
  

	10.	MISCELLANEOUS. 

 10.1    No Agency.    It is agreed and understood that neither party is the agent, representative or partner of the other, and neither party has any
authority or power to bind or contract in the name of or to create any liability against the other in any way or for any purpose pursuant to this Agreement. Nothing contained in this Agreement shall be construed to give either party the power to
direct and control the day-to-day activities of the other, constitute the parties as partners, joint venturers, principal and agent, employer and employee, co-owners, or otherwise as participants in a joint undertaking, or allow either party to
create or assume any obligation on behalf of the other party for any purpose whatsoever. 

 SLSI-201304IA001-2 

 

 10.2    Amendment; Waiver; Remedies
Cumulative.  Any agreement on the part of a party hereto to any extension or waiver of any provision hereof shall be valid only if set forth in an instrument in writing signed on behalf of such party. A waiver by a party hereto of the
performance of any covenant, agreement, obligation, condition, representation or warranty shall not be construed as a waiver of any other covenant, agreement, obligation, condition, representation or warranty. A waiver by any party of the
performance of any act shall not constitute a waiver of the performance of any other act or an identical act required to be performed at a later time. This Agreement may not be amended, modified or supplemented except by written agreement of all of
the parties hereto. All rights and remedies existing under this Agreement are cumulative to, and not exclusive of, any rights or remedies otherwise available. 
 10.3    Counterparts; Facsimile Signature.  This Agreement may be executed in any number of counterparts, each of which shall be considered one and the same agreement
and shall become effective when all counterparts have been signed by each of the parties and delivered to the other party, it being understood that the parties need not sign the same counterpart. Either party may execute this Agreement by facsimile
or scanned signature and the other party will be entitled to rely on such facsimile or scanned signature as conclusive evidence that this Agreement has been duly executed by such party. 

10.4    Governing Law. This Agreement (and any claims or disputes arising out of or
related hereto or to the transactions contemplated hereby or to the inducement of any party to enter herein, whether for breach of contract, tortious conduct or otherwise and whether predicated on common law, statute or otherwise) shall in all
respects be governed by, and construed in accordance with, the laws of the State of New York of the United States of America, including all matters of construction, validity and performance, in each case without reference to any conflict of law
rules that might lead to the application of the laws of any other jurisdiction. 

10.5    Dispute Resolution. (a) In the event there is a dispute between Purchaser
and Seller regarding this Agreement, or with respect to the performance by a Seller of its obligations hereunder (whether in respect of a matter which has previously been resolved pursuant to this Section 10.5 or otherwise), prior to any
party instituting any action or claim or pursuing any other remedy hereunder, the parties shall attempt in good faith to reach agreement on a resolution of the dispute. If such attempts are unable to resolve the dispute, the parties shall seek to
resolve the dispute in accordance with the provisions of this Section 10.5. 
  

	 	i)	 The party which is the disputing party (the “Disputing Party”) shall send a written notice describing the dispute or issue (the
“Dispute Notice”) to the other party (the “Notice Receiver”). A) Within fifteen (15) days of the Notice Receiver’s receipt of a Dispute Notice, the Parties shall conduct a meeting, attended by an executive designated by
each Party (a “Step One Meeting”). If resolved at the Step One Meeting or at any other time prior to the expiration of such 15-day period, the Disputing Party shall re-send the original
Dispute Notice to the other Party with a written and signed acknowledgment that it has been withdrawn. B) The matter shall be considered unresolved if at any time the parties agree in writing that it is unresolved or the original Dispute Notice has
not been withdrawn 

 SLSI-201304IA001-2 

 

	 	 
within fifteen (15) days after conclusion of the Step One Meeting 

  

	 	ii)	 If the matter remains unresolved after the Step One Meeting, either of the Parties may initiate any claim or pursue or exercise any of its
rights or remedies hereunder, at law or in equity pursuant to Section 10.5 (b) 

  

	 	(b)	 All disputes arising out of or in connection with this Agreement shall be finally settled under the Rules of Arbitration of the International
Chamber of Commerce by one or more arbitrators appointed in accordance with the said Rules. The place of arbitration shall be Singapore. The language of the arbitral proceedings shall be English. Judgment upon any award(s) rendered by the
arbitrator(s) may be entered in any court having jurisdiction thereof. The arbitrator(s) are authorized to include in the award an allocation to any party of such costs and expenses, including attorneys’ fees, as the arbitrator shall deem
reasonable. Nothing in this Agreement shall prevent either party from seeking provisional measures from any court of competent jurisdiction, and any such request shall not be deemed incompatible with the agreement to arbitrate or a waiver of the
right to arbitrate. The parties undertake to keep confidential all awards in their arbitration, together with all materials in the proceedings created for the purpose of the arbitration and all other documents produced by another party in the
proceedings not otherwise in the public domain, save and to the extent that disclosure may be required of a party by legal duty, to protect or pursue a legal right or to enforce or challenge an award in legal proceedings before a court or other
judicial authority. 

 10.6    Binding Effect;
Assignment.  This Agreement binds and benefits the parties and their respective permitted successors and assigns. No party hereto may assign any of its rights or delegate any of its obligations under this Agreement without the prior
written consent of the other party; provided, however, the Purchaser may assign any of its rights or obligations under this Agreement to any Affiliate of the Purchaser without the consent of the Seller. 

10.7    No Third-Party Beneficiaries.  This Agreement shall inure to the benefit of
and be binding upon the parties hereto and their respective successors and assigns. Nothing in this Agreement, expressed or implied, is intended to or shall confer on any Person other than the parties hereto or their respective successors and
assigns, any rights, remedies or liabilities under or by reason of this Agreement. 

10.8    Force Majeure.  The Seller shall not be liable for any interruption of a
Service or delay or failure to perform under this Agreement if such interruption, delay or failure results from strikes (other than in relation to the relevant Seller’s own workforce), riots, fires, floods, storm, earthquakes, power outages,
telecommunications or network outages or limitations, acts of God, war, governmental action or any other causes beyond its reasonable control (“Force Majeure”). In any such event, the Purchaser and the Seller’s obligations hereunder
in respect of the Service affected by Force Majeure shall be postponed for such time as the performance is suspended or delayed on account of such Force Majeure event and the parties shall seek to identify and implement a commercially reasonable
alternative to minimize any interruption in the provision of those Services hereunder. Each of the Purchaser and the Seller will promptly notify 

 SLSI-201304IA001-2 

 

 
the other in writing upon learning of the occurrence of such event of Force Majeure. Upon the cessation of the Force Majeure event, each of the Purchaser and the Seller will use all commercially
reasonable effort to resume its performance with the least practicable delay 

10.9    Notices.  All notices, consents, waivers and other communications required
or permitted by this Agreement shall be in writing and shall be deemed given to a party (a) on the date of delivery if delivered by hand or sent by facsimile or e-mail with confirmation of transmission by the transmitting equipment, (b) on
the first Business Day following the date of dispatch if delivered by an internationally-recognized next-day courier service, or (c) on the fifth Business Day following the date of mailing if delivered by registered or certified mail, return
receipt requested, postage prepaid, in each case to the following addresses, facsimile numbers or e-mail addresses and marked to the attention of the persons (by name or title) designated below (or to such other address, facsimile number, e-mail
address or person as a party may designate by notice to the other parties pursuant to this Section 10.9): 
 If to the Seller,
to: 
 Samsung Electronics Co., Ltd. 
 SR3 Bldg. 
 San #24 Nongseo-Dong, Giheung-Gu 

Yongin City, Gyeonggi Do, Korea 449-711 
 Fax no.: 
 Attention: 

with a copy to (which copy shall not constitute notice): 
 [              ] 
 if to the Purchaser, to: 
  IXYS Intl Limited 

c/o IXYS Corporation 
 1590 Buckeye Drive 
 Milpitas, CA 95035 

Fax no. +1.408.416.0224 
 Attention: Uzi Sasson 
 with a copy to (which copy shall not constitute notice):

  Latham & Watkins LLP 
 140 Scott Drive 
 Menlo Park, CA 94025 

Fax no.: +1.650.463.2600 
 Attention: Luke Bergstrom 
 10.10  Construction;
Usage. 

 SLSI-201304IA001-2 

 

 (a)      Interpretation. In
this Agreement, unless a clear contrary intention appears: 
 (i)       the singular
number includes the plural number and vice versa; 
 (ii)      reference to any Person
includes such Person’s successors and assigns but, if applicable, only if such successors and assigns are not prohibited by this Agreement, and reference to a Person in a particular capacity excludes such Person in any other capacity or
individually; 
 (iii)     reference to any gender includes each other gender; 

(iv)     reference to any agreement, document or instrument means such agreement, document or instrument
as amended or modified and in effect from time to time in accordance with the terms thereof; 

(v)     “hereunder,” “hereof,” “hereto,” and words of similar import shall
be deemed references to this Agreement as a whole and not to any particular Article, Section or other provision hereof; 

(vi)    “including” means including without limiting the generality of any description preceding
such term; 
 (vii)   “Dollars” and “US$” shall mean United States dollars; and

 (viii)   references to documents, instruments or agreements shall be deemed to refer as well to all
addenda, exhibits, schedules or amendments thereto. 

(b)      Headings.    The headings contained in this Agreement
are for the convenience of reference only, shall not be deemed to be a part of this Agreement and shall not be referred to in connection with the construction or interpretation of this Agreement. 

10.11  Severability.  Any term or provision of this Agreement which is invalid or
unenforceable in any jurisdiction shall, as to that jurisdiction, be ineffective to the extent of such invalidity or unenforceability and shall not render invalid or unenforceable the remaining terms and provisions of this Agreement or affect the
validity or enforceability of any of the terms or provisions of this Agreement in any other jurisdiction. If any provision of this Agreement is so broad as to be unenforceable, the provision shall be interpreted to be only so broad as is
enforceable. 
 10.12  Mutual Drafting.  The parties hereto have been represented by
counsel who have carefully negotiated the provisions hereof. As a consequence, the parties do not intend that the presumptions of any laws or rules relating to the interpretation of contracts against the drafter of any particular clause should be
applied to this Agreement and therefore waive their effects. The provisions of this Agreement shall be interpreted in a reasonable manner to effect the intent of the parties. 

 SLSI-201304IA001-2 

 

 10.13  Exhibits. The Services Exhibit is hereby
incorporated into this Agreement and are hereby made a part hereof as if set out in full herein. 

10.14  Entire Agreement.    This Agreement and the other Transaction Documents
constitute the entire agreement among the parties hereto with respect to the subject matter hereof and thereof and terminate and supersede all prior agreements and understandings, oral and written, among the parties hereto with respect to the
subject matter hereof and thereof. 
 IN WITNESS WHEREOF, each party has
caused this Agreement to be executed by its duly authorized representative as of the date first written above. 
  

									
	IXYS INTL LIMITED	 		 	SAMSUNG ELECTRONICS CO., LTD.
					
	By:	 	 /s/ Uzi Sasson
	 		 	By:	 	 /s/ Byunghoon Suh

			
	Name:  Uzi Sasson	 		 	Name:  Byunghoon Suh
			
	Title:   Director	 		 	Title:   Senior Vice President

 EXHIBIT A 

SERVICES EXHIBIT 
 The Seller
agrees to provide the following Services during the applicable periods of time set forth below: 
  

	1.	Information Technology (IT) and Finance Services  

  

							
	Service Description:	 		 	•	 	Finance - Provide data so Purchaser can develop customer invoicing processes.
				
		 		 	•	 	IT - Provide data to assist with Purchaser’s transition of enabling transactions (wafer orders, etc...) within Purchaser’s Oracle system.
		
	Fees:	 	Purchaser will pay Seller’s reasonable expenses and cost of travel as set forth in the Seller Expense Table.
		
	Service Period:	 	***.

  

	2.	Operational Services. 

  

							
	Service Description:	 	During the Service Period, Seller will:
				
		 		 	1)	 	Assist Purchaser with introductions to all vendors including those associated with wafer preparation, flash programming, sort, assembly, and final test processes.
				
		 		 	2)	 	If necessary, assist and train Purchaser in the transition of wafer preparation, flash programming, sort, assembly, and final test processes to Purchaser.
				
		 		 	3)	 	Deliver and assign Customer POs (as defined in the Foundry Services Agreement) for WIP Products (as defined in the Foundry Services Agreement) to Purchaser
				
		 		 	4)	 	Notwithstanding anything contrary to this Agreement, the vendors addressed in this provision shall not include vendors that: i) are not related with the Business as of the Closing
Date; and ii) are Seller’s raw material or equipment vendors (other than vendors of raw materials or equipment related to the assembly or the packaging of integrated

  
 ***Certain confidential
information contained in this document, marked with 3 asterisks (***), has been omitted and filed separately with the Securities and Exchange Commission pursuant to Rule 24b-2 of the Securities Exchange Act of 1934, as amended. 

 SLSI-201304IA001-2 

 

							
		 		 		 	circuits).
		
	Fees:	 	 Purchaser will pay Seller’s reasonable expenses and cost of travel as set forth in the Seller Expense Table.

		
	Pass-Through Expenses:	 	 Cost of packaging, freight and insurance and subcontractor fees.

		
	Service Period:	 	 ***

  

	3.	Quality and Reliability Services: 

 (a)      Warranty Claims and Returns: 
  

			
	Service Description:	 	 During the Service Period, Seller will perform customer failure analysis of the IXYS Business Products (as defined in
Product License Agreement) and provide the results of that analysis to Purchaser. If necessary, Seller will request a solution to the appropriate design or software provider.

 
 For avoidance of doubt, Purchaser shall directly manage
all matters relating to customer relations, including, but not limited to, taking any claims of, or complaints regarding, any product defects from customers in connection with such IXYS Business Products.

		
	Fees:	 	 Except for subcontractor fees, Seller will provide all services at no charge until one year after the Closing Date. After this period, Purchaser will pay
Seller’s reasonable expenses and cost of travel as set forth in the Seller Expense Table.

		
	Pass-Through Expenses:	 	 For amounts actually paid by Seller, Purchaser will reimburse Seller for third-party fees associated with the Quality and Reliability Services. Purchaser will
also pay Seller’s reasonable expenses and cost of travel as set forth in the cost table.

		
	Service Periods:	 	 ***

  

	4.	Development Services. 

  

											
	Service Description:	 	 During the Service Period, Seller will perform the following services

				
		 		 	(i)	 	complete development of the following *** Products: ***,

  
 ***Certain confidential
information contained in this document, marked with 3 asterisks (***), has been omitted and filed separately with the Securities and Exchange Commission pursuant to Rule 24b-2 of the Securities Exchange Act of 1934, as amended. 

 SLSI-201304IA001-2 

 

											
		 		 		 		 	the development to include:
						
		 		 		 		 	a.	 	Management of the design subcontractor(s).
						
		 		 		 		 	b.	 	Report development milestones to the Purchaser
(1st F/O, test report, tape out, quality reports, and
other reports customarily produced by Seller in the design of similar devices).
						
		 		 		 		 	c.	 	Enter into development agreements with subcontractors for the development of the *** Product components such as the verification and test programs.
				
		 		 	(ii)	 	 Complete transitional development of the following *** Products: ***, the development to
include:

						
		 		 		 		 	a.	 	Management of the design subcontractor (if applicable).
						
		 		 		 		 	b.	 	Report development milestones to Purchaser (1st F/O, test report, tape out, quality reports, and other reports customarily produced by Seller in the design of similar
devices).
						
		 		 		 		 	c.	 	Enter into development agreements with subcontractors for the development of the *** product components such as the verification and test programs.
				
		 		 	(iii)	 	Provide development training:
						
		 		 		 		 	a.	 	Technical workshops regarding: product designs, design techniques, development process, product transition, and documents, and usage of the licensed In House Design
Tools,
						
		 		 		 		 	b.	 	Modification or creation of new documentation with respect to the Business Products, and
						
		 		 		 		 	c.	 	The Parties shall discuss and agree on the detailed development schedule for the development training.
		
	Fees:	 	 Fees relating to Section 4(i): Purchaser will pay any amounts, including incentive fee payments, owed to vendors under the Transferred Contracts
relating to the development work described

  
 ***Certain confidential
information contained in this document, marked with 3 asterisks (***), has been omitted and filed separately with the Securities and Exchange Commission pursuant to Rule 24b-2 of the Securities Exchange Act of 1934, as amended. 

 SLSI-201304IA001-2 

 

			
		 	 in Section 4(i). Purchaser shall be responsible for all other development fees set forth in the Transferred Contracts
relating to the *** Products.
  
 Fees relating
to Section 4(ii): Purchaser will pay a development fee of USD $***. This fee includes subcontracting fees, the costs of mask sets, and verification fees. The payment of USD $*** will be made within thirty days after receipt of Seller’s invoice
which shall be issued by Seller after the Closing Date.
  
 Purchaser will also pay Seller’s reasonable expenses and cost of travel as set forth in the Seller Expense Table.

		
	Service Period:	 	 ***, or, for the products described in Sections 4(i) and 4(ii), *** from the mass production date of the last of such products to enter mass production,
whichever is later.

  

	5.	Sales Support Services. 

  

			
	Service Description:	 	 During the Service Period, Seller will (i) arrange major customer meetings, and (ii) provide personal introductions to Solution Partners, key customer, Sales
Representatives and Distributors relating to the Business, and (iii) provide data and information relating to 4-bit and 8-bit microcontroller sales and marketing; provided that such customer, Solution Partner, key customer, Sales Representative and
Distributors will be selected by parties’ consent; provided that key customer means a customer who directly buys Business Products from the Seller.

		
	Fees:	 	 Purchaser will pay Seller’s reasonable expenses and cost of travel as set forth in the Seller Expense Table.

		
	Service Period:	 	 ***.

  

	6.	Design Transition Services. 

  

			
	Service Description:	 	 During the Service Period, Seller shall provide Purchaser with such information, cooperation and assistance to effect a smooth and seamless transition of foundry
services to a third party designated by Purchaser (a “Successor”) (such information, cooperation and assistance, “Transition Assistance”). Transition Assistance shall include: (a) providing know-how, technical information and
other

  
 ***Certain confidential
information contained in this document, marked with 3 asterisks (***), has been omitted and filed separately with the Securities and Exchange Commission pursuant to Rule 24b-2 of the Securities Exchange Act of 1934, as amended. 

 SLSI-201304IA001-2 

 

			
		 	 appropriate information concerning the transfer and transition of the foundry services to Purchaser; and (b) other services as reasonably requested by
Purchaser.

		
	Fees:	 	 Purchaser will pay Seller’s reasonable expenses and cost of travel as set forth in the Seller Expense Table.

		
	Service Period:	 	 ***.

 7. Seller Expense Table. 
     Payroll Table 
 (USD, per hour) 

 

											
	
Position
  
	 	Korea	 	China	 	Singapore	 	US	 	EU
	
E3/G3/S3/M3
  

 
	 	 ***

 
	 	 ***

 
	 	 ***

 
	 	 ***

 
	 	 ***

 

	
E4/G4/S4/M4

 
	 	 ***

 
	 	 ***

 
	 	 ***

 
	 	 ***

 
	 	 ***

 

	
E5/G5/S5/M5/M6

 
	 	 ***

 
	 	 ***

 
	 	 ***

 
	 	 ***

 
	 	 ***

 

	
E6/G6/S6/M7

 
	 	 ***

 
	 	 ***

 
	 	 ***

 
	 	 ***

 
	 	 ***

 

 Travel Fee: USD $*** per day per person (This amount includes out-of pocket money, meals, ground transfer
fee, and accommodations fee. Airfare fee will be paid separately, but now hourly expenses will not be paid while service providers are traveling, including while on the airplane). 

  
 ***Certain confidential
information contained in this document, marked with 3 asterisks (***), has been omitted and filed separately with the Securities and Exchange Commission pursuant to Rule 24b-2 of the Securities Exchange Act of 1934, as amended. 

 SLSI-201304IA001-2 

 

	8.	Purchase Order Agency. 

  

			
	Service Description:	 	 During the Service Period and until August 31, 2013, i) Seller may directly provide Business Products in place of
Purchaser, without transfer of the purchase orders to Purchaser, that are/were ordered by purchase orders existing at Closing Date or prior to Closing date; and ii) Seller may receive purchase orders of Business Products from customers in place of
Purchaser and provide the Business Products to the customer. Profit Share (defined hereafter) shall be monthly paid by Seller to Purchaser. On August 31, 2013 all Customer purchase order will be delivered and assigned to Purchaser.

 
 Profit Share

 
 (a) ***.

 
 (b) ***.

		
	Fees:	 	 Purchaser will pay Seller’s cost of travel as set forth in the Seller Expense Table.

		
	Service Period:	 	 ***.

  
 ***Certain confidential
information contained in this document, marked with 3 asterisks (***), has been omitted and filed separately with the Securities and Exchange Commission pursuant to Rule 24b-2 of the Securities Exchange Act of 1934, as amended. 

 SCHEDULES 
 Schedule 1.3 
 Service Coordinator Contact Information: 

For Seller: 
 Name: 

Title: 
 Phone: 

Facsimile: 
 Email: 

For Purchaser: 
 Name:  David
Staab 
 Title:  Vice President of R&D and MCU Architecture of Zilog, Inc. 
 Phone:  +1.408.457.9087 
 Facsimile:  +1.408.416.0223 

Email:dstaab@zilog.com

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00220-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00220-of-00352.parquet"}]]