Document:

Settlement Agreement and Release

 EXHIBIT 10.6 
 SETTLEMENT AGREEMENT AND RELEASE 
 This Settlement Agreement and Release (this
“Agreement”) is made and entered into by and between Adept Technology, Inc. (“Adept”) and Tri-Valley Technology Campus, LLC (“Tri-Valley”). Adept and Tri-Valley are referred to collectively as the “Parties,”
or each is referred to individually as a “Party.” This Agreement is a new agreement between the Parties as of October 16, 2008. 
 WHEREAS, Tri-Valley is the owner and lessor of real property located at 3011, 3055 and 3077 Triad Drive, Livermore, California (the “Property”); 
 WHEREAS, Adept is currently a tenant at 3011 Triad Drive at the Property; 
 WHEREAS, Adept entered into a
lease with Tri-Valley Campus I, LLC (“Predecessor Landlord”) for certain space at 3011 Triad Drive at the Property, on or about September 18, 2000, amended by an Amendment to Lease on or about August 6, 2003 (together, the
“Lease”); 
 WHEREAS, Adept and Tri-Valley entered a Lease Termination Agreement on or about December 16, 2007 (the
“Lease Termination Agreement,” or “LTA”); 
 WHEREAS, Tri-Valley filed three actions against Adept: Tri-Valley Campus
I, LLC v. Adept Technology, Inc., Case No. C08 01424, filed in the Superior Court of the State of California in and for the County of Contra Costa on or about May 30, 2008 and dismissed on or about July 31, 2008; Tri-Valley
Technology Campus, LLC v. Adept Technology, Inc., Case No. VG08401019, filed in the Superior Court of the State of California in and for the County of Alameda on or about July 29, 2008; and Tri-Valley Technology Campus, LLC v. Adept
Technology, Inc., Case No. VG08401607, filed in the Superior Court of the State of California in and for the County of Alameda on or about July 31, 2008 (the “Actions”); 
 WHEREAS, the Actions concern a dispute between the Parties concerning the force and effect of the Lease Termination Agreement, the rights and obligations
of Adept with respect to its Lease to occupy 3011 Triad Drive at the Property, and the tort claims that Tri-Valley asserts against Adept in the Actions (the “Dispute”); 
 WHEREAS, the Parties wish to resolve their differences concerning the Dispute and bring an end to the Actions; 
 WHEREAS, the Parties have consulted with their legal counsel regarding their rights relating to the Dispute and the Actions and the facts that gave rise
to the Dispute and the Actions; and; 
 WHEREAS, each Party understands and agrees that this Agreement is a compromise and settlement of
disputed claims and that this Agreement should not be construed as an admission of liability by any Party; 

 NOW, THEREFORE, with the intent and purpose of satisfying and settling all claims between the Parties
relating specifically to the Dispute and the Actions, and in consideration of the promises contained in this Agreement, it is agreed as follows: 
 1. Remaining Lease Term and Lease Termination. The Parties agree that Adept shall have the right to occupy 3011 Triad Drive at the Property through and including January 31, 2009 in accordance with the terms and conditions of
the Lease. Adept agrees that it will take commercially reasonable steps in an effort to vacate the Property on or before December 31, 2008, but in any event no later than January 31, 2009. The Lease shall terminate on the earlier of either
January 31, 2009 or the date that Adept actually vacates the Property (the “Lease Termination Date”). Adept shall continue to pay rent, additional rent, and all other sums due pursuant to the Lease, through and including the Lease
Termination Date, provided, however, that Adept’s share of any amounts that Adept is obligated to pay under the Lease, including Direct Operating Expenses (as that term is defined in Paragraphs 6.4 and 6.5 of the Lease) or any CAM charges,
shall be assessed at a level no higher than the average monthly amount charged to Adept during the first eight months of 2008. The Parties further agree that in the event that Adept continues to occupy the Property on or after January 1, 2009,
Adept’s base rent shall be two (2) times Adept’s currently agreed-upon base rent, paid on a per diem basis commencing January 1, 2009 and terminating on the Lease Termination Date. Adept shall have no obligation whatsoever to pay
any rent, additional rent, and any other sums due pursuant to the Lease, or make any other payment pursuant to the Lease, after the Lease Termination Date, attributable to the period after the Lease Termination Date. Tri-Valley states that it
intends to substantially renovate the Property after Adept vacates the Property. The Parties agree that Tri-Valley shall not assess any additional fees, costs, or penalties associated with the condition of the Property when Adept vacates the
Property and Tri-Valley agrees to waive any and all claims for damage against Adept relative to the Property; provided, however, that Adept shall be responsible for (1) removing from the Property any hazardous materials that Adept may have
introduced to the Property; (2) removing all of Adept’s furniture, fixtures, and equipment from the Property; and (3) sweeping the Property to broom clean condition. 
 2. Settlement Payments. As consideration for this Agreement, the sufficiency of which is acknowledged by each Party, the Parties agree that
within two (2) business days after counsel for Adept has received a fully executed copy of this Agreement, including all attachments, Adept shall pay Tri-Valley Two-Hundred Fifty Thousand Dollars ($250,000.00) as consideration for the covenants
and obligations of Tri-Valley under this Agreement (the “First Settlement Payment”). The First Settlement Payment shall be made by wire transfer directly to Tri-Valley’s account in the name CalSmart, LLC at Northern Trust, Chicago
Bank, ABA Number 071000152, Account Number 89346. As further consideration for this Agreement, Adept shall deposit in a neutral escrow account with Stewart Title and Escrow, an additional Two-Hundred Fifty Thousand Dollars ($250,000.00) as
consideration for the covenants and obligations of Tri-Valley under this Agreement (the “Second Settlement Payment”) within two (2) business days after the date that Adept actually vacates the Property, and in any event no later than
February 3, 2009. Within two (2) business days after the later of the dates that Adept has deposited the Second Settlement Payment into the neutral escrow account and the date that Adept actually vacates the Property, Tri-Valley shall
execute and file Requests for Dismissal of the Actions, pursuant to Paragraph 3. Within two (2) business days of Tri-Valley filing the executed Requests for Dismissal of the Actions as described in Paragraph 3, Adept shall release the Second
Settlement Payment and any interest thereon to Tri-Valley in its entirety. In the 

  

 Page 2 of 8 

 
event that Tri-Valley files the executed Requests for Dismissal on or before the date that Adept actually vacates the Property, Adept shall pay the Second
Settlement Payment directly to Tri-Valley’s account by wire transfer, in the same manner as described herein for payment of the First Settlement Payment, within two (2) business days after Adept actually vacates the Property, and in any
event no later than February 3, 2009. 
 3. Stay of the Actions and Dismissal of the Actions With Prejudice. The Parties agree
that the Actions shall be stayed for all purposes through and including the Lease Termination Date, and that the Parties shall execute and Tri-Valley shall file the attached Requests for Stay (attachments A, B, and C) within two (2) business
days after the execution of this Settlement Agreement and Release. The Parties further agree that Tri-Valley shall execute and file the attached Requests for Dismissal (attachments D and E) no later than two (2) business days after the later of
the dates that Adept has deposited the Second Settlement Payment into the neutral escrow account and the date that Adept has actually vacated the Property. Tri-Valley agrees to sign all papers and to take any further action reasonably necessary to
accomplish these Dismissals of the Actions. Counsel for Tri-Valley shall promptly provide notice of the entry of judgment dismissing both Actions with prejudice to counsel for Adept. 
 4. Right to Possession Commencing February 1, 2009. The Parties agree that in the event that Adept continues to occupy the Property on
February 1, 2009, Tri-Valley shall have the right to immediate possession of the Property on or after February 1, 2009. The Parties further agree that in the event that Adept continues to occupy the Property on February 1, 2009,
Tri-Valley shall have the right to submit a Stipulated Judgment confirming Tri-Valley’s right to immediate possession of the Property on or after February 1, 2009, which is attached hereto as Attachment F. The Parties agree that the
Stipulated Judgment shall be null and void and have no legal effect whatsoever if Adept vacates the Property on or before January 31, 2009. The Parties further agree that the Stipulated Judgment shall provide only for immediate possession
commencing on February 1, 2009, but shall not provide for any other form of relief. The Stipulated Judgment provides that only Tri-Valley’s right to such possession shall be immediately enforceable in the Superior Court for the County of
Alameda. Any other dispute arising in any way from the Stipulated Judgment or this Settlement Agreement and Release shall be enforced as provided in this Settlement Agreement and Release. 
 5. Lease Termination Agreement. The Parties agree that the Lease Termination Agreement is superseded by this Agreement and has no legal effect
whatsoever. 
 6. Releases By All Parties. As consideration for this Agreement each Party agrees to release and waive any claims each
of them may have against each other relating to the Lease, the Lease Termination Agreement, the Dispute, and the Actions, subject to and as set forth below in sub-paragraphs a and b below. The releases described in this Paragraph 6 are not intended
to be general mutual releases of any and all claims as between Adept and Tri-Valley, but instead limited releases of those claims relating specifically to the Lease, the Lease Termination Agreement, the Dispute, and/or the Actions. The releases
described in this Paragraph 6 are not intended to release either of the Parties from their respective future obligations under the Lease accruing from and after the date of execution of this Agreement, including without limitation, Adept’s
obligation to pay real estate taxes and assessments with respect to the Property, whether paid in advance or in arrears (“Future Obligations”), and is limited to the release described in this Paragraph 6. The releases described in this
Paragraph 6 shall be effective upon the last of the 

  

 Page 3 of 8 

 
following occurring: Adept makes the First Settlement Payment and Second Settlement Payment, pursuant to Paragraph 2; Tri-Valley dismisses the Actions with
prejudice; and Adept actually vacates the Property. For clarification, in the event that Adept occupies the Property after January 31, 2009, the releases described in this Paragraph 6 shall not apply to the extent that Tri-Valley shall be
permitted to assert claims against Adept to the extent allowed by law related to Adept’s detention of the Property after January 31, 2009. 
  

	 	a.	Release by Tri-Valley Technology Campus, LLC. Tri-Valley, for itself and each of its officers, directors, partners, associates, trustees, managers, property managers,
investment managers, direct and indirect shareholders and members, agents, employees, affiliates, divisions and subsidiaries, forever releases and discharges Adept and all of its current and former partners, associates, officers, directors,
employees, agents, attorneys, accountants, insurers, predecessors-in-interest, successors-in-interest, assigns, affiliates, divisions and subsidiaries (the “Tri-Valley Releasee”), of and from all disputes, claims, causes of action,
actions, judgments, liens, indebtedness, costs, damages, obligations, attorneys’ fees, losses, liabilities and demands of whatever kind and character (“Claims”) that now exist, or may exist or have existed, from the beginning of time
to the date of this Agreement, known or unknown, foreseen or unforeseen, liquidated or unliquidated, potential or actual, that relate specifically to the Actions, or were alleged in the Actions, or otherwise arise out of the Lease, the Lease
Termination Agreement, and/or the Dispute, except with respect to the Parties’ respective Future Obligations. This release includes any and all Claims relating to or arising out of any local, state, federal or foreign statute, ordinance,
regulation, order, or common law with respect to the Lease, the Lease Termination Agreement, and/or the Dispute, except with respect to the Parties’ respective Future Obligations. It is further understood and agreed that Tri-Valley waives all
rights with respect to the Lease, the Lease Termination Agreement, and/or the Dispute against the Tri-Valley Releasee under California Civil Code Section 1542 and under any similar laws, except with respect to the Parties’ respective
Future Obligations. Section 1542 reads as follows: 

 A general release does not extend to claims which the creditor
does not know or suspect to exist in his favor at the time of executing the release, which if known by him must have materially affected his settlement with the debtor. 
 Notwithstanding the provisions of Section 1542 and any similar laws, and for the purpose of implementing a full and complete release and discharge
of the Tri-Valley Releasee of all Claims, Tri-Valley expressly acknowledges that this Agreement and release are intended to include in their effect all of Tri-Valley’s Claims against the Tri-Valley Releasee as they relate to the Lease, the
Lease Termination Agreement, the Dispute, and the Actions, except with respect to the Parties’ respective Future Obligations, whether or not Tri-Valley knows or suspects such to exist at the time of execution of this Agreement and that this
Agreement contemplates the extinguishment of all such Claims that relate to the Lease, the Lease Termination Agreement, the Dispute, and the Actions. 
  

 Page 4 of 8 

	 	b.	Release by Adept Technology, Inc. Adept, for itself and each of its officers, directors, partners, associates, trustees, managers, property managers, investment managers,
direct and indirect shareholders and members, agents, employees, affiliates, divisions and subsidiaries, forever releases and discharges Tri-Valley and all of its current and former partners, associates, officers, directors, employees, agents,
attorneys, accountants, insurers, predecessors-in-interest, successors-in-interest, assigns, affiliates, divisions and subsidiaries (the “Adept Releasee”), of and from all disputes, claims, causes of action, actions, judgments, liens,
indebtedness, costs, damages, obligations, attorneys’ fees, losses, liabilities and demands of whatever kind and character (“Claims”) that now exist, or may exist or have existed, from the beginning of time to the date of this
Agreement, known or unknown, foreseen or unforeseen, liquidated or unliquidated, potential or actual, that relate specifically to the Actions, or were alleged in the Actions, or otherwise arise out of the Lease, the Lease Termination Agreement,
and/or the Dispute, except with respect to the Parties’ respective Future Obligations. This release includes any and all Claims relating to or arising out of any local, state, federal or foreign statute, ordinance, regulation, order, or common
law with respect to the Lease, the Lease Termination Agreement, and/or the Dispute, except with respect to the Parties’ respective Future Obligations. It is further understood and agreed that Adept waives all rights with respect to the Lease,
the Lease Termination Agreement, and/or the Dispute against the Adept Releasee under California Civil Code Section 1542 and under any similar laws, except with respect to the Parties’ respective Future Obligations. Section 1542 reads
as follows: 

 A general release does not extend to claims which the creditor does not know or suspect to exist in his favor
at the time of executing the release, which if known by him must have materially affected his settlement with the debtor. 
 Notwithstanding the provisions of Section 1542 and any similar laws, and for the purpose of implementing a full and complete release and discharge of the Adept Releasee of all Claims, Adept expressly acknowledges that this Agreement
and release are intended to include in their effect all of Adept’s Claims against the Adept Releasee as they relate to the Lease, the Lease Termination Agreement, the Dispute, and the Actions, except with respect to the Parties’ respective
Future Obligations, whether or not Adept knows or suspects such to exist at the time of execution of this Agreement and that this Agreement contemplates the extinguishment of all such Claims that relate to the Lease, the Lease Termination Agreement,
the Dispute, and the Actions. 
 7. Waiver of Attorneys’ Fees, Costs, and Expenses. The Parties agree that each Party will bear
its own attorneys’ fees, costs, and expenses incurred in any way in connection with the Dispute and/or the Actions, and that each Party waives any right it might have to seek any such fees, costs, and/or expenses from any other Party.

  

 Page 5 of 8 

 8. Authority to Settle. Tri-Valley warrants that it has the power, right and authority to settle
and release fully and completely all Claims that it is settling and releasing in this Agreement. Adept warrants that it has the power, right and authority to settle and release fully and completely all Claims that it is settling and releasing in
this Agreement. 
 9. Standalone Agreement. Each Party acknowledges and agrees that this Agreement is a new, separate agreement as of
October 16, 2008, and does not constitute an amendment to the Lease other than as specifically provided herein. 
 10. Successors in
Interest. Each Party agrees that this Agreement shall be binding upon each Party and any successors-in-interest to each Party. 
 11.
No Assignment. Each Party warrants and represents that it has not assigned or transferred to any other person any of the claims, causes of action, or other matters that are released by this Agreement. 
 12. Entire Agreement. This Agreement contains the entire agreement and understanding concerning the subject matter of the Agreement between the
Parties, and supersedes and replaces all prior negotiations and proposed settlement agreements, written or oral. Each of the Parties to this Agreement acknowledges that no other party to this Agreement, nor any agent or attorney of any such party,
has made any promise, representation or warranty, express or implied, not contained in this Agreement to induce any Party to execute this Agreement. The Parties further acknowledge that they are not executing this Agreement in reliance on any
promise, representation or warranty not contained in this Agreement. It is expressly understood and agreed that this Agreement may not be altered, amended, modified or otherwise changed in any respect, except by a writing duly executed by two
officers from each Party, or two officers from each of the Parties’ respective successors or assigns in interest, or their authorized representatives. 
 13. Confidentiality. The Parties and their counsel, and each of them, agree, to the extent permitted by law, that all agreements made and orders entered during the course of the Dispute relating to the
confidentiality of information shall survive this Agreement. This includes, without limitation, that the transcript of the deposition taken on July 23, 2008, shall remain confidential in its entirety, may not be used in any action or other
legal proceeding for any reason, and shall not be disclosed to any person for any reason. Tri-Valley agrees that it shall destroy any and all copies of the deposition in its possession or that it has provided to any other person; provided, however,
that Tri-Valley’s counsel may maintain one copy of the transcript for archival purposes only. The Parties further agree that the terms of this Agreement and all discussions of the Parties’ respective counsel relating to this Agreement are
strictly confidential and are not to be disclosed to any third parties unless they have obtained the express written consent of each of the other Party or unless disclosure is required by applicable rules, regulations, statutes,
or court order. Neither the existence of the settlement nor the existence of this Agreement shall be confidential notwithstanding any other provisions herein. 
 14. Advice of Counsel. Each Party represents that it has been represented, or has had the opportunity to be represented, by independent legal counsel of its own choice, throughout all 

  

 Page 6 of 8 

 
of the negotiations that preceded the execution of this Agreement and that it has executed this Agreement with the consent and upon the advice of such
counsel, or that it has had the opportunity to seek such consent and advice. Each Party acknowledges that it has read this Agreement and assents to all the terms and conditions contained in this Agreement without any reservations and that it has
had, or has had the opportunity to have had, the same explained to it by its own counsel, who have answered any and all questions which have been asked of them, or which could have been asked of them, with regard to the meaning of any of the
provisions of this Agreement. 
 15. No Admissions. By entering into this Agreement, no Party intends to make, nor shall be deemed to
have made, any admission of any kind. The Parties agree that they are entering into this Agreement solely for the purposes of avoiding the costs of further litigation of the Action. This Agreement is the product of informed negotiations and
compromises of previously stated legal positions. Nothing contained in this Agreement shall be construed as an admission by any Party as to the merit or lack of merit of any particular claim or defense. Any statements made in the course of
negotiations have been and shall be without prejudice to the rights of the Parties in any disputes or transactions with any other person or entity not party to this Agreement. 
 16. Governing Law. This Agreement shall in all respects be interpreted, enforced, and governed by and under the internal laws of the State of
California. 
 17. Enforcement of Agreement. The Parties agree that any action to enforce or interpret this Agreement may be brought
exclusively in arbitration before Justice Edward A. Panelli in San Francisco, California. No breach of any duty or obligation by any Party hereunder shall entitle any other Party to rescind or terminate this Agreement, except as provided expressly
herein. In any such arbitration proceeding, the prevailing Party shall recover its reasonable attorneys’ fees and costs. In any such arbitration proceeding, this Agreement may be introduced into evidence to establish and enforce the settlement
reached by the Parties. In the event that Justice Panelli is not available, the Parties agree that another arbitrator with JAMS in San Francisco, California, may hear any such dispute. 
 18. Counterparts. This Agreement may be executed in one or more counterparts, each of which shall be an original as against any Party who signed
it, and all of which shall constitute one and the same document. 
 19. Construction. The language of this Agreement shall be
construed as a whole, according to its fair meaning and intendment, and not strictly for or against any Party, regardless of who drafted or was principally responsible for drafting the Agreement of any specific terms or conditions hereof. This
Agreement shall be deemed to have been drafted by all Parties, and no Party shall urge otherwise. The Parties expressly waive any presumption that might otherwise apply to construe the terms of this Agreement against any Party on the basis that the
Party drafted this Agreement. 
 20. Headings. The headings of the sections of this Agreement are for convenience of reference only
and shall not affect the meaning or interpretation of this Agreement. 
 21. Authorization to Execute Agreement. Each Party who
executes this Agreement represents and warrants that the individual executing this Agreement on behalf of such Party does so with the knowledge and express approval and authorization of the Party on whose behalf the individual executes this
Agreement. 
  

 Page 7 of 8 

							
	October 16, 2008	 		  	TRI-VALLEY TECHNOLOGY CAMPUS, LLC
		 		  	By:	 	Calsmart LLC, its Manager
		 		  	By:	 	RREEF America LLC, its Investment Manager
				
		 		  	By:	 	 /s/ Ross T. Berry

		 		  	Its	 	Ross T. Berry, Managing Director
			
	October 16, 2008	 		  	TRI-VALLEY TECHNOLOGY CAMPUS, LLC
		 		  	By:	 	Calsmart LLC, its Manager
		 		  	By:	 	RREEF America LLC, its Investment Manager
				
		 		  	By:	 	 /s/ Ross T. Berry

		 		  	Its	 	Ross T. Berry, Managing Director
			
		 		  	TRI-VALLEY TECHNOLOGY CAMPUS, LLC
		 		  	By:	 	Calsmart LLC, its Manager
		 		  	By:	 	RREEF America LLC, its Investment Manager
				
		 		  	By:	 	 /s/ Darrell Campos

		 		  	Its	 	Director
			
	October 16, 2008	 		  	ADEPT TECHNOLOGY, INC.
				
		 		  	By:	 	 /s/ John Dulchinos

		 		  		 	John Dulchinos
			
		 		  	Its President and Chief Executive Officer
				
		 		  	By:	 	 /s/ Lisa Cummins

		 		  		 	Lisa Cummins
			
		 		  	Its Vice-President of Finance and Chief Financial Officer

  

 Page 8 of 8Lease Agreement - Registrant and Park Lake Apartments, L.P.

 EXHIBIT 10.7 
 LEASE AGREEMENT 
 THIS LEASE AGREEMENT (as more particularly defined below, this
“Lease”) is entered into as of the Date, and by and between the Landlord and Tenant, identified in Section 1.1 below. 
 1.
BASIC LEASE DEFINITIONS, EXHIBITS AND ADDITIONAL DEFINITIONS. 
  

	1.1	Basic Lease Definitions. 

 In this Lease, the
following capitalized terms have the meanings indicated. 
 (a) “Date” means the date of full
execution of this Lease, which is October 10, 2008. 
 (b) “Landlord” means Park Lake Apartments,
L.P., a California limited partnership. 
 (c) “Tenant” means Adept Technology, Inc., a Delaware
corporation. 
 (d) “Building” means the office building in which the Premises are located, which
Building is located at 5960 Inglewood Drive, Pleasanton, California 94588. 
 (e) “Parking Facilities”
means the parking facilities (including surface parking) and structures located on the Land. 
 (f) “Initial Premises” means those premises consisting of a portion of the east end of the first (1st) floor of the Building, identified on Exhibit A-1, and consisting of approximately 10,475 Rentable Square Feet (“First Floor Premises”) and the north end of the third (3rd) floor, identified on Exhibit A-2, and consisting of approximately 23,389 Rentable Square Feet (“Third Floor
Premises”). The Initial Premises is hereby agreed and stipulated for all purposes to be approximately 33,864 Rentable Square Feet. 
 (g) “Use” means general office use, research and development and uses incidental thereto. 
 (h) “Term” means the duration of this Lease, which will be seven (7) years, beginning on the Rent Commencement Date and ending on the Expiration Date, unless terminated earlier or extended
further as provided in this Lease; provided that if the Rent Commencement Date is not the first day of a month, the Term and the first Lease Year will be greater than twelve (12) months by the number of days from the Rent Commencement Date to
the last day of the month in which the Rent Commencement Date occurs. 
 (i) “Expiration Date” means
the date which is seven (7) years after the Rent 

 
Commencement Date, as may be extended pursuant hereto; provided that if the Rent Commencement Date is not the first day of a month, the Expiration Date will
be seven (7) years plus the number of days between the date the Rent Commencement Date occurs to the last day of the month in which the Rent Commencement Date occurs. 
 (j) “Rent Commencement Date” means the date that is the earliest of (a) the date on which Tenant occupies any
portion of the Initial Premises and begins conducting business therein (it being understood that if Tenant accesses the Initial Premises pursuant to Section 3.5 below for the sole purpose of readying the Initial Premises, it shall not be deemed
to have commenced business operations in the Initial Premises), (b) the date on which the Tenant Improvements in the Initial Premises are Substantially Completed (as defined in Exhibit B-1 attached hereto), or (c) the date on
which the Tenant Improvements in the Initial Premises would have been Substantially Completed but for the occurrence of any Tenant Delay Days (as defined in Exhibit B-1 attached hereto). The estimated Rent Commencement Date is
November 21, 2008. 
 (k) “Base Rent” means the base annual rental equal to the product of
(i) the Annual Base Rental Rate per Rentable Square Foot set forth below multiplied by (ii) the Rentable Square Feet in the Premises as existing from time, payable in accordance with Section 4.1: 
  

							
	 Lease Year(s)
	  	Annual Base Rental Rate per
Rentable Square Foot, net of
electrical and janitorial which are
paid 100% by Tenant	  	Monthly Base Rental
	 1
	  	$	20.40	  	$	57,568.80
	 2
	  	$	21.01	  	$	59,290.22
	 3
	  	$	21.64	  	$	61,068.08
	 4
	  	$	22.29	  	$	62,902.38
	 5
	  	$	22.96	  	$	64,793.12
	 6
	  	$	23.65	  	$	66,740.30
	 7
	  	$	24.36	  	$	68,743.92

 Upon request of Landlord following the Rent Commencement Date, Tenant shall execute an Occupancy
Estoppel Certificate in the form of Exhibit C. 
 (l) “Tenant’s Share” shall be a
percentage equal to 100 multiplied by a fraction the numerator of which is equal to the aggregate Rentable Square Feet of the Premises and the denominator of which is the aggregate Rentable Square Feet of the Building. Tenant’s Share shall
initially be 32.74%. The foregoing calculation is based on an aggregate number of Rentable Square Feet of the Building of 103,444. 
 (m) “Base Year” means Landlord’s Fiscal Year ending December 31, 2008. 
 (n)
“Landlord’s Address” means: 
 c/o Streamline 
 7901 Stoneridge Drive, Ste 205 
 Pleasanton, CA 94588 
 Attn: Property Manager for 5960 Inglewood Drive, Pleasanton,
California 94588 
  

 2 

 (p) “Tenant’s Notice Address” means: 
 Prior to the Rent Commencement Date: 
 3011 Triad Drive, Livermore, CA 94551, Attention: Sue Carlson-Lim 
 After the Rent
Commencement Date: 
 At the Premises, Suite 300. 
 (s) “Tenant’s Invoice Address” means: 
 At the Premises, Suite 300. 
 (t) “Brokers” means Colliers International, representing both Landlord and Tenant, acting in a dual capacity, whom will be paid by Landlord in accordance with separate written agreements.

 (u) “Liability Insurance Amount” means $5,000,000.00. 
 (v) “Tenant’s Electrical Share”, with respect to utilities for the Premises, shall be a percentage equal to
100 multiplied by a fraction the numerator of which is equal to the aggregate Rentable Square Feet of the Premises and the denominator of which is the aggregate Rentable Square Feet of the Building that are occupied by tenants. 
  

	1.2	Additional Definitions. 

 The following capitalized
terms when used in this Lease have the meanings set forth below or in the referenced section of the Lease: 
 “Additional Rent” means the Rent payable according to Section 4.2. 
 “Affiliate” of an entity shall mean and refer to any entity controlling, controlled by, or under common control with another such entity, where control means the ownership, directly or indirectly, of more than fifty
percent (50%) of the voting securities of any entity, or possession of the right to vote, in the ordinary direction of its affairs, more than fifty percent of the voting interest in, any entity. 
 “Building Business Hours” means the hours from 7:00 a.m. to 6:00 p.m. on Monday through Friday, excluding
Holidays. 
  

 3 

 “Building Standard” means the type, brand and/or quality of
materials Landlord designates from time to time to be the minimum quality to be used in the Building or the exclusive type, grade or quality of material to be used in the Building and shall refer to the then-current standard described in
Landlord’s most recently published schedule of Building Standard or, if no such schedule has been published, to the standard which commonly prevails in and for the entire Building. 
 “Common Areas” means the interior and exterior common and public areas located on the Land and in the Building for
the non-exclusive use in common by Tenant, Landlord and other tenants, and their employees, guests, customers, agents and invitees, including the north and south lobbies of the Building, outdoor landscape areas, the outdoor barbeque and recreation
area, the Parking Facilities the hallways and elevator lobbies on multi-tenant floors. The existing reception desk shall be removed from the north lobby and thereafter no tenant in the Building may have a reception desk in the north lobby.

 “Exclusive Systems” means mechanical, plumbing, electrical, and other systems installed by Tenant
that exclusively serve the Premises (such as, by means of illustration only, supplemental heating, ventilating and air conditioning (“HVAC”) systems, plumbing for non-Building Standard restrooms exclusively used by Tenant (but excluding
those restrooms provided as part of the Building Standard finished by Landlord), and wall plugs and switches within the Premises). For clarification, the base building systems (mechanical, plumbing, electrical, HVAC, or other systems), including the
portion thereof located within the Premises, shall not be considered Exclusive Systems. 
 “Expenses”
means, subject to Exhibit F and the other limitations set forth herein, the reasonable costs and expenses attributable to the Project that Landlord reasonably and actually incurs because of or in connection with the ownership,
operation, management, repair, replacement, and maintenance of the Project and Landlord’s personal property used in connection therewith, determined in accordance with generally accepted accounting principles consistently applied
(“GAAP”), provided, however, that Landlord may change its accounting methods so long as any adjustments made to affect such change do not result in Tenant paying more than the amount Tenant would pay hereunder if Landlord
used GAAP, and without duplication, including, without limitation, the following types of expenses as limited below: 
 (i)
Wages, salaries, related taxes, unemployment and workers compensation insurance, fees, benefits, and reimbursable expenses of all personnel of Landlord to the extent directly engaged in operating, managing and repairing the Project, up to the level
of area manager, to the extent not included in the management fee. 
 (ii) Cost of all supplies and materials and equipment
rental directly related to owning, operating and maintaining the Project. 
  

 4 

 (iii) Cost of all utilities for the Project other than electricity, including, without
limitation, water, sewer, gas, heating, lighting, air conditioning, and ventilating (including chilled water). 
 (iv) Cost of
all maintenance, common area janitorial, and other similar service agreements for the Project. 
 (v) Premiums for insurance
relating to the Project that Landlord actually carries, including the cost of casualty and liability insurance applicable to the Project and Landlord’s personal property used in connection therewith. 
 (vi) A market based management fee, not to exceed five percent (5%) of total Rent from the Project. 
 (vii) All governmental charges and fees of whatsoever nature, whether now existing or subsequently created, assessed against Landlord and
attributable to the Project or its occupancy or operation, but excluding franchise, income or similar taxes of Landlord (but not excluding such taxes to the extent imposed in the future wholly or partially in lieu of present real estate, ad valorem,
or similar taxes). 
 (viii) That portion of the following items that is allocable to the Land and Building: all property
taxes and assessments, special or otherwise, levied upon or with respect to the Land or Building, the personal property either used exclusively in connection with the operation and management of the Land or Building or the cost of which is allocated
to such operation and management of the Land or Building, and the rents and additional charges payable by tenants of the Building, and imposed by any taxing authority having jurisdiction; all taxes, levies and charges which may be assessed, levied
or imposed in replacement of, or in addition to, all or any part of property taxes or assessments as revenue sources, and which in whole or in part are measured or calculated by or based upon the Land or Building, the fee estate of Landlord or the
tenants of the Building, or the rents and other charges payable by such tenants; capital and place-of business taxes, and other similar taxes assessed relating to the Building; and any reasonable expenses incurred by Landlord in attempting to reduce
or avoid an increase in taxes, including, without limitation, reasonable legal fees and costs and any increase in any of the foregoing based upon construction of improvements on the Building or Land or changes in ownership (as defined in the
California Revenue and Taxation Code) of the Building or Land (collectively, “Taxes”). Notwithstanding the foregoing, Taxes shall not include Consolidated Reassessment District 1993-2 and Consolidated Reassessment District
1993-3 (“Special Assessments”), Tenant shall not be obligated to pay for the Special Assessments (and the same shall not be included in the Base Year). 
 (ix) Costs of repairs and maintenance to the Project, excluding such costs to the extent Landlord is specifically reimbursed by the
proceeds of insurance, by Tenant or other tenants of the Building, or that are actually paid by other third parties. 
  

 5 

 (x) Capital expenditures made (1) to reduce Expenses but only to the extent of the
actual savings realized, (2) to comply with any governmental requirements adopted on or after the Date, or (3) to replace part of the Project that requires replacement because the useful life of that part has ended and such replacement is
necessary for the proper operation of the Project, provided that all permitted capital expenditures under this (ix)(2) and (ix)(3) (together with a financing charge of four and one half (4.5%) percent over the average Prime Rate in effect
during the Fiscal Year in which such capital expenditure was made) will be amortized for purposes of the Lease over the useful life of the related capital item as reasonably determined by Landlord using customary commercial property management
practices, on a straight line basis. 
 (xi) Any common area maintenance charges, taxes, assessments, fees and other costs
payable by Landlord under the HBPOA covenants, conditions and restrictions or association documents existing as of the Date governing the Land or Building and future changes in any such documents to the extent that any additional Expenses are
reasonably allocable to the Building or Land. 
 Notwithstanding anything to the contrary, in no event will Expenses include
any expenditure excluded from Expenses under Exhibit F or under any other provision of this Lease. In all instances, the calculation of Expenses for each Fiscal Year during the Term shall be consistent with the calculation of Expenses
for the Base Year, including, but not limited to, the type of expenditures to be included in Expenses and the allocation of any Expenses to the Building. 
 “Fiscal Year” means Landlord’s fiscal year, which begins on January 1st and ends on December 31st of each calendar year and may be changed at Landlord’s discretion at any
time after December 31, 2008; provided, however, that if Landlord elects to change its Fiscal Year, (a) the new Fiscal Year shall be 12 calendar months, (b) such election shall not cause Expenses for the Base Year to be modified, and
(c) Additional Rent shall continue to be calculated on the basis that the Base Year is the calendar year beginning January 1, 2008 and ending December 31, 2008. 
 “Force Majeure” means any acts of God, governmental restriction, strikes, labor disturbances, shortages of
materials or supplies, or any other cause or event beyond the parties’ reasonable control (but not because of insolvency, lack of funds or other financial cause), by which either party is hindered or prevented from performance of any act under
this Lease, then performance of such act shall be excused for the period during which such performance is rendered impossible; and time for performance shall be extended accordingly. However, Force Majeure shall not release either party from any
obligation under this Lease. No such delay shall constitute an actual or constructive eviction in whole or in part, or entitle Tenant to any abatement or diminution of rents or other charges due except as otherwise provided herein, or impose any
liability upon Landlord or its agents because of inconvenience to Tenant or injury to or interruption of Tenant’s business. 
  

 6 

 “HBPOA” means Hacienda Business Park Owners Association.

 “Holidays” means New Years Day, Memorial Day, Independence Day (Fourth of July), Labor Day,
Thanksgiving Day, and Christmas Day. 
 “Initial Term” means the initial approximately seven
(7) year term of the Lease, which may be extended by Tenant pursuant to Section 27 and/or terminated by Tenant pursuant to Section 30. 
 “Land” means the real property described in Schedule 1 attached hereto, less any portions that are actually conveyed separately from the Building by Landlord from time to time. 
 “Laws” means any and all present or future federal, state or local laws, statutes, ordinances, rules, regulations
or orders of any and all governmental or quasi-governmental authorities having jurisdiction. 
 “Lease” means this Lease Agreement and all Exhibits hereto. 
 “Lease
Year” means each successive period of 12 calendar months during the Term from and after the Rent Commencement Date; provided that if the Rent Commencement Date is not the first day of a month, the first Lease Year will be greater than
12 months by the number of days from the Rent Commencement Date to the last day of the month in which the Rent Commencement Date occurs. 
 “Person” means any individual, corporation, partnership, limited liability company or other business entity. 
 “Premises” means the area of the Building leased to Tenant pursuant to this Lease. This Lease provides Tenant
certain options and rights to lease additional space in the Building and upon Tenant leasing any such space, the area of such space shall be deemed to be a part of the Premises. 
 “Prime Rate” means the rate of interest announced from time to time by Citibank, N.A., or any successor to it, as
its prime rate. If Citibank, N.A. or any successor to it ceases to announce a prime rate, Landlord will designate a reasonably comparable financial institution for purposes of determining the Prime Rate. If more than one Prime Rate is announced by
Citibank, NA. or its successor, then Landlord shall designate the applicable Prime Rate. 
 “Project”
means the Land, the Building and all other improvements located on the Land, including the Parking Facilities. 
  

 7 

 “Rent” means the Base Rent, Additional Rent and all other amounts
required to be paid by Tenant under this Lease. 
 “Rentable Square Feet” means “rentable
area” as determined pursuant to 1996 BOMA (ANSI Z65.1-1996) calculation methodology. 
 “Tenant
Improvements” means the First Floor Tenant Improvements (as defined in Exhibit B-1 attached hereto) and the Third Floor Tenant Improvements (as defined in Exhibit B-2 attached hereto). 
  

	1.3	Terminology/Exhibits. 

 All references in this Lease
to “Section” or “Exhibit” shall refer to the section of this Lease or the exhibit to this Lease in which such reference appears, unless otherwise expressly stated. All references to herein, hereof, hereto, hereunder or similar
terms shall be deemed to refer to the entire Lease. As used in this Lease, the term “including” shall mean “including but not limited to”. Unless otherwise expressly set forth in this Lease, whenever the terms
“consent”, “approval” or similar term is used in this Lease with respect to a party, it shall include the implied covenant of such party not to unreasonably withhold, condition or delay its consent. The Exhibits listed at the end
of the table of contents are attached to and incorporated in this Lease. In the event of any inconsistency between such Exhibits and the terms and provisions of this Lease, the terms and provisions of the main portion of this Lease (i.e., the
portions of the Lease other than the Exhibits) will control. 
 2. GRANT OF LEASE. 
  

	2.1	Demise. 

 Subject to the terms, covenants,
conditions and provisions of this Lease, Landlord leases to Tenant and Tenant leases from Landlord the Premises, together with the non-exclusive right to use the Common Areas and the Parking Facilities, for the Term. In addition, Tenant shall have
the non-exclusive right to the use plenums, risers, electric closets, ducts, shafts, flues, conduits and pipes within the Building for the installation and maintenance of conduits, cables and other devices, supplemental HVAC and other facilities,
and for other purposes in connection with the Tenant’s use and occupancy of the Premises (but only to the extent such facilities were intended for the use proposed by Tenant or can accommodate such proposed use without interfering with the use
of such facilities by any other tenant or prospective tenant for the use for which such facilities were intended), at no additional cost, subject to Landlord’s reasonable right of approval, but such approval is subject to the restriction that
Tenant shall not have utilization of such facilities to the extent greater than Tenant’s Share unless otherwise consented to in writing by Landlord. 
  

	2.2	Quiet Enjoyment. 

 Landlord covenants that during
the Term, Tenant will have quiet and peaceable 

  

 8 

 
possession of the Premises, subject to the terms, covenants, conditions and provisions of this Lease, and Landlord will not unreasonably disturb such
possession except as expressly permitted in this Lease. Landlord shall take all reasonable steps to minimize disruption to Tenant’s business and use of the Premises arising out of activities of Landlord, its contractors, other tenants, and
their contractors, including enforcing all Rules and Regulations against other tenants in the Building and their contractors. 
  

	2.3	Landlord And Tenant Covenants. 

 Subject to the
terms hereof, Landlord covenants to observe and perform all of the terms, covenants and conditions applicable to Landlord in this Lease and Tenant covenants to pay the Rent when due, and to observe and perform all of the terms, covenants and
conditions applicable to Tenant in this Lease. 
 3. TERM. 
  

	3.1	Commencement. 

 This Lease is a binding lease
effective on the Date; however, Tenant’s obligation to pay Rent hereunder shall not commence until the Rent Commencement Date. 
  

	3.2	Delivery of Premises. 

 Landlord shall deliver the
Initial Premises to Tenant with the Tenant Improvements Substantially Completed; provided, however, that such delivery shall not relieve Landlord of its obligation to fully complete the Punch List Items (as hereinafter defined). 
 Notwithstanding anything to the contrary contained in this Lease, if Landlord has not delivered the Initial Premises to Tenant with the Tenant
Improvements Substantially Completed on or before the date which is one hundred twenty (120) days after the mutual execution and delivery of this Lease (but subject to a day-for-day extension for Tenant Delay Days or events of Force Majeure)
(the “Build-Out Period”), then upon the Rent Commencement Date, Tenant shall receive an abatement of Base Rent equal to the number of days of delay between the expiration of the Build-Out Period until the date Landlord
delivers the Initial Premises to Tenant with the Tenant Improvements Substantially Completed. 
 Notwithstanding anything to the contrary
contained in this Lease, if Landlord has not delivered the Initial Premises to Tenant with the Tenant Improvements Substantially Completed on or before the date which is one hundred eighty (180) days after the mutual execution and delivery of
this Lease (but subject to a day-for-day extension for Tenant Delay Days or events of Force Majeure) (the “Outside Date”), then Tenant, as its sole and exclusive remedy, may terminate this Lease by written notice to Landlord
to be given not later than ten (10) business days after expiration of the Outside Date, whereupon any monies previously paid by Tenant to Landlord shall be reimbursed to Tenant. 
  

 9 

	3.3	Surrender. 

 Upon the expiration or other
termination of the Term, Tenant will immediately vacate and surrender possession of the Premises in good order, repair and condition, except for ordinary wear and tear and damage due to fire or other casualty. Upon the expiration or other
termination of the Term, Tenant agrees to remove all of Tenant’s office furniture, office equipment and other similar personal property and, unless requested otherwise by Landlord prior to the expiration of the Term or concurrently with any
other termination of the Lease, the Purchased Furniture (as hereinafter defined). At Landlord’s option, to be exercised by written notice to Tenant delivered no less than thirty (30) days after Tenant’s written request for such
election, which request of Tenant may be delivered no earlier than twelve (12) months prior to the expiration of the Term or concurrently with any other termination of the Lease, Tenant shall remove (a) any Alterations, the removal of
which was requested by Landlord in written notice to Tenant at the time of the installation of such Alterations (regardless of whether Landlord’s approval of such Alterations was required hereunder); provided, however that Tenant shall not be
required to remove: (i) the initial Tenant Improvements in the Initial Premises, and (ii) any tenant improvements existing in any ROFO Space (as hereinafter defined) at the time Tenant leases the same pursuant to a right granted under this
Lease, and (b) any Alterations as to which Tenant failed to request, at the time of the installation thereof, that Landlord notify Tenant in writing whether Landlord would require Tenant to remove such Alterations upon expiration or other
termination of this Lease. 
 Notwithstanding the foregoing, in no event shall Tenant be required to remove (1) any Alterations as to
which (A) Tenant requested, at the time of the installation thereof, that Landlord notify Tenant in writing whether Landlord would require Tenant to remove such Alterations and (B) Landlord either failed to respond to such request, did not
specifically identify the Alterations in question as Alterations that Tenant would be required to remove, or indicated as such time that the Alterations in question need not be removed, (2) the initial Tenant Improvements in the Initial
Premises, or (3) any tenant improvements existing in any ROFO Space at the time Tenant leases the same pursuant to a right granted under this Lease. 
 Without limiting Tenant’s obligations with respect to the condition of the Premises upon expiration or termination, Tenant will pay Landlord within thirty (30) days of written demand the cost of repairing
any damage to the Premises or Building caused by the installation or removal of any such items. Any of Tenant’s personal property remaining in the Premises shall become the property of Landlord unless Landlord requires Tenant to remove the
same. 
  

	3.4	Holding Over. 

 Tenant understands that it does not
have the right to hold over at any time and Landlord may exercise any and all remedies at law or in equity to recover possession of the Premises in the event Tenant holds over without Landlord’s consent. If Tenant holds over in all or any
portion of the Premises after the Expiration Date, unless otherwise agreed to 

  

 10 

 
by Landlord and Tenant, the monthly Base Rent for the Premises shall increase to one hundred twenty five percent (125%) of the Annual Base Rental Rate
which was applicable immediately prior to the Expiration Date, and Tenant will be bound by all of the other terms, covenants and agreements of this Lease. Tenant shall not be liable to Landlord for any consequential damages incurred by Landlord as a
result of such hold over, including any lost profits resulting therefrom. 
  

	3.5	Early Access. 

 Landlord shall provide Tenant with
limited access to the Premises for the approximately fourteen (14) calendar day period prior to the date when Landlord estimates that the Tenant Improvements will be Substantially Completed for the sole purpose of permitting Tenant to ready the
Premises for Tenant’s occupancy, at such times as are reasonably specified by Landlord so that Tenant’s access does not materially interfere with the performance of the Tenant Improvements in the Premises. Tenant’s access to the
Premises during the period of time prior to the Rent Commencement Date shall be subject to all the provisions of this Lease (including the Rules and Regulations and such other rules and regulations as Landlord may reasonably impose), other than the
payment of Rent and the expiration date of the Lease shall not be advanced by such access by Tenant of the Premises prior to the Rent Commencement Date. Tenant shall not interfere with Landlord’s performance of the Tenant Improvements in the
Premises. 
  

	3.6	Delay with Respect to Rent Commencement Date. 

 Notwithstanding the definition of Rent Commencement Date and Section 3.5 above, if the Tenant Improvements in the Initial Premises are not Substantially Completed by November 21, 2008 (other than as a result of Tenant Delay Days),
then Tenant shall be provided with access to the Initial Premises pursuant to Section 3.5 on the later to occur of: (i) January 1, 2009 or (ii) the date that is approximately fourteen (14) calendar day period prior to the
date when Landlord estimates that the Tenant Improvements will be Substantially Completed and the Rent Commencement Date shall not occur until the later of: (i) January 15, 2009 or (ii) the date that the Tenant Improvements in the
Initial Premises are Substantially Completed. If the Tenant Improvements in the Initial Premises are not Substantially Completed by November 21, 2008 because of Tenant Delay Days, then this Section 3.6 shall have not apply. 
 4. RENT. 
  

	4.1	Base Rent. 

 Commencing on the Rent Commencement
Date and then throughout the Term, Tenant agrees to pay Landlord Base Rent according to the following provisions. Base Rent during each Lease Year (or portion of a Lease Year) described in Section 1.1(k) will be payable in equal monthly
installments, in advance, on or before the first day of each and every month. However, if the Rent Commencement Date is not the first day of a month or if the Term ends on other than the last day of a month, Base Rent for such month will be prorated
based on the number of days in such month. The first monthly installment of Base Rent shall be payable concurrently with the execution of this Lease by Tenant. 
  

 11 

	4.2	Additional Rent. 

 Commencing on the thirteenth (13th) month of the Lease Term, Tenant agrees to pay Landlord, as Additional Rent,
in the manner provided below for each Fiscal Year subsequent to the Base Year that contains any part of the Term, Tenant’s Share of the amount by which Expenses for such Fiscal Year exceed Expenses for the Base Year (“Additional
Expenses”). 
 (a) Estimated Payments. Landlord will use commercially reasonable efforts to deliver to
Tenant, prior to or as soon as practicable after the beginning of each Fiscal Year subsequent to the Base Year but in no event later than four months after the beginning of each Fiscal Year, a line by line item statement reasonably detailing all
actual Expenses incurred during the immediately preceding Fiscal Year, Tenant’s Share of the Additional Expenses (if any) for the preceding Fiscal Year, Landlord’s good faith estimate of the Expenses to be incurred during the ensuing
Fiscal Year and Tenant’s Share of the estimated Additional Expenses (if any) for the ensuing Fiscal Year. On or before the first day of each calendar month following receipt of such notice, and during the ensuing Fiscal Year, Tenant shall pay
to Landlord, in advance, an amount equal to (i) the difference between (A) Tenant’s Share of Landlord’s estimate of Additional Expenses for such Fiscal Year and (B) all Additional Rent paid to date by Tenant attributable to
such Fiscal Year, divided by (ii) the number of full calendar months remaining in such Fiscal Year. Until such notice is given with respect to the ensuing Fiscal Year, Tenant will continue to pay on the basis of the prior Fiscal Year’s
estimate until the month after the month in which such notice is given. If at any time or times, in Landlord’s good faith, reasonable judgment, Tenant’s Share of Additional Expenses for the then-current Fiscal Year will vary from
Landlord’s estimate by more than five percent (5%), Landlord may, by written notice to Tenant, revise its estimate for such Fiscal Year and subsequent payments by Tenant for such Fiscal Year will be based upon the revised estimate. 

(b) Annual Settlement. Landlord will deliver to Tenant its reasonably itemized statement of Tenant’s Share of Additional
Expenses actually incurred for the preceding Fiscal Year within a commercially reasonable period of time after the end of the Fiscal Year (but not to exceed one hundred twenty (120) days). If on the basis of such statement Tenant owes an amount
that is less than the estimated payments previously made by Tenant for such Fiscal Year, Landlord will either refund such excess amount to Tenant within thirty (30) days after delivery of such statement or shall credit Tenant such excess amount
against the next payment(s), if any, due from Tenant to Landlord provided that in no instance will there be any credit or refund below the Base Year amount for Expenses. If on the basis of such statement Tenant owes an amount that is more than the
estimated payments previously made by Tenant for such Fiscal Year, Tenant will pay the deficiency to Landlord within thirty (30) days after the delivery of such statement. If this Lease terminates on a day other than the last day of a Fiscal
Year, Tenant’s Share of Additional Expenses applicable to the Fiscal Year in which termination of this Lease occurs will be prorated on the basis of the number of days within such Fiscal Year prior to the termination date. 
  

 12 

 (c) Final Payment. Tenant’s obligation to pay the Additional Rent and
Landlord’s obligation to refund or credit any overpayment of Additional Rent provided for in this Section 4.2 which is accrued but not paid for periods prior to the expiration or early termination of the Term will survive such expiration
or early termination. Prior to or as soon as practicable after the expiration or early termination of the Term, Landlord may submit an invoice to Tenant stating Landlord’s estimate of the amount by which Tenant’s Share of Additional
Expenses through the date of such expiration or early termination will exceed Tenant’s estimated payments of Additional Rent for the Fiscal Year in which such expiration or termination has occurred or will occur. Tenant will pay the amount of
any such excess to Landlord within thirty (30) days after the date of Landlord’s invoice and Landlord will promptly refund any overpayment to Tenant, provided that in no instance will there be any refund below the Base Year amount for
Expenses. 
 (d) Gross-Up of Expenses and Taxes. For each Fiscal Year during the Term in which the Building is less
than one hundred percent (100%) occupied, the amount by which those Expenses that vary with occupancy (e.g., cleaning costs and utilities) would have increased had the Building been one hundred percent (100%) leased and occupied and
operational and had all Building services been provided to all tenants will be reasonably determined and the amount of such increase will be included in Expenses for such Fiscal Year (including the Base Year). Management fees shall not be grossed
up. Landlord shall provide to Tenant the tax assessments and bills for the Project within ten (10) business days after Tenant’s request for the same. 
 (e) Challenge Regarding Taxes; Proposition 8 Protests. Landlord may, if Landlord elects, challenge with the appropriate
governmental authority the amount of Taxes (or related valuation) related to the Land and Building, including Proposition 8 assessment reviews, challenges and protests. In addition, Landlord shall, upon written request by Tenant, use commercially
reasonable diligence to challenge Taxes (or related valuation), including Proposition 8 assessment reviews, challenges and protests. As provided in item (viii) of the definition of Expenses in Section 1.2, reasonable expenses incurred by
Landlord in attempting to reduce or avoid an increase in Taxes shall be included in Expenses. A reduction in Taxes obtained by Landlord, if any, shall not affect the Taxes included in Expenses for the Base Year. 
  

	4.3	Other Taxes. 

 Tenant will reimburse Landlord within
thirty (30) days of Tenant’s receipt of a written demand from Landlord for any and all of the following taxes payable by Landlord (other than income, franchise or similar taxes and taxes included in Taxes) whether or not now customary or
within the contemplation of Landlord and Tenant: (a) upon, measured by or reasonably attributable to the cost or value of Tenant’s equipment, furniture, fixtures and other personal property located in the Premises; (b) upon or with
respect to the possession, leasing, operation, management, maintenance, alteration, repair, use or 

  

 13 

 
occupancy by Tenant of the Premises or any portion of the Premises; and (c) upon this transaction or any document to which Tenant is a party creating or
transferring an interest or an estate in the Premises. 
  

	4.4	Terms of Payment. 

 All Base Rent, Additional Rent
and other Rent will be paid to Landlord in lawful money of the United States of America, at Landlord’s Address or to such other person or at such other place as Landlord may from time to time designate in writing, without notice or demand and
without right of deduction, abatement or setoff, except as otherwise expressly provided in this Lease. 
  

	4.5	Late Charge and Interest on Late Payments. 

 All
amounts payable under this Lease by Tenant to Landlord, if not paid within five (5) days of the date when due if concerning regular payments of Base Rent and Additional Rent and otherwise five days after receipt of notice from Landlord that
payment is past due, will (a) incur a late charge equal to the greater of five percent (5%) of the amount past due or Five Hundred and No/100 Dollars ($500.00), and (b) bear interest from the due date until paid at the lesser of the
highest interest rate permitted by applicable law or two percent (2%) in excess of the then-current Prime Rate. Provided, however, that Tenant shall be entitled to receive one (1) past due notice from Landlord during any consecutive twelve
(12) month period of the Term, or any extension thereof, before any late charge shall be incurred by Tenant hereunder. 
  

	4.6	Right to Accept Payments. 

 No receipt by Landlord
of an amount less than Tenant’s full amount due will be deemed to be other than payment “on account”, nor will any endorsement or statement on any check or any accompanying letter effect or evidence an accord and satisfaction.
Landlord may accept such check or payment without prejudice to Landlord’s right to recover the balance or pursue any right of Landlord. No payments by Tenant to Landlord after the expiration or other termination of the Term, or after the giving
of any notice (other than a demand for payment of money) by Landlord to Tenant, will reinstate, continue or extend the Term or make ineffective any notice given to Tenant prior to such payment. After notice or commencement of a suit, or after final
judgment granting Landlord possession of the Premises, Landlord may receive and collect any sums of Rent due under this Lease, and such receipt will not void any notice or in any manner affect any pending suit or any judgment obtained. 

 

	4.7	Tenant’s Right To Audit. 

 (a)
Landlord shall maintain complete and accurate books and records detailing all Expenses (including Taxes) for not less than the three (3) Fiscal Years preceding the then current Fiscal Year. Landlord may keep the books and records at the
Building or at Landlord’s regional office. Upon thirty (30) days written notice, Tenant 

  

 14 

 
and/or its representatives shall have the right, at Tenant’s expense, to examine, copy, and audit, during normal business hours at the place where
Landlord maintains such records, Landlord’s books and records pertaining to the Expenses for the then immediately preceding Fiscal Year (including the Base Year, but with respect to the Base Year, Tenant shall only have one (1) right to
audit the same) to enable Tenant to verify the accuracy thereof. Landlord shall reasonably cooperate with Tenant in any such examination. If it is determined that the Expenses reported by Landlord are in excess of one hundred five
(105%) percent of the actual amount of Expenses with respect to any Fiscal Year, then if (a) Landlord fails to dispute such finding, or (b) Landlord agrees with such finding, or (c) following a dispute of Tenant’s audit by
Landlord the calculation selected by the arbitrator, if submitted to arbitration (as provided below) or the reconciled audits, still evidence that Tenant was overcharged by more than five percent (5%) as set forth above, then Tenant’s
reasonable actual out-of-pocket, third party costs of said audit shall be payable by Landlord on demand. If it is determined, as set forth in the preceding sentence that Tenant was not overcharged by more than five percent (5%), then Landlord’s
reasonable actual out-of-pocket, third party costs of monitoring and responding to said audit shall be payable by Tenant on demand. Any overpayment by Tenant shall be credited to Tenant and any undercharge shall be paid by Tenant within thirty
(30) days. Failure by Tenant to contest or dispute the allocation of Additional Rent (i) within ninety (90) days following Landlord’s delivery of the Expense reconciliation statement pursuant to Section 4.2 for a particular
Fiscal Year, or (ii) with respect to the final Fiscal Year during the Term, within ninety (90) days following the delivery of the Expense reconciliation statement for the final Fiscal Year, (A) is deemed a waiver of Tenant’s
audit or dispute right and any right to contest the Additional Rent charges (undercharges or overcharges) with respect to the Fiscal Year in question (but not with respect to any other Fiscal Year); and (B) is deemed acceptance of the
Additional Rent charges as submitted to and reviewed by Tenant for such Fiscal Year. Subject to the preceding sentence, the foregoing provisions shall survive termination or expiration of the Lease. In the event Tenant exercises its audit rights as
provided above and Landlord and Tenant cannot reconcile their respective calculations of Expenses within forty-five (45) days following the delivery by Tenant to Landlord of the results of Tenant’s audit, either Landlord or Tenant can
cause the calculation of Expenses to be submitted to arbitration by delivering written notice to the other of such election. In such event, Landlord and Tenant shall, within thirty (30) days following the election by either party to submit the
calculation to arbitration, mutually agree upon a third party arbitrator satisfactory to both parties to render a final determination of the Expenses. In the event Landlord and Tenant are unable to mutually agree upon an arbitrator within such
period, the parties shall then apply to the American Arbitration Association or any successor thereto for the designation of an arbitrator to render a final determination of the Expenses. In either event the arbitrator shall (1) be a certified
public accountant licensed in the State of California, (2) have at least ten (10) years experience in the field of commercial office operations, (3) not have represented either Landlord or Tenant during the preceding (5) years
(other than with respect to other audits conducted by either party for the Project), and (4) be generally experienced and competent in determining and calculating the proper allocation of operating expenses among tenants in office buildings
similar to the Building. The arbitrator shall, within thirty (30) days following his or her appointment, determine which 
  

 15 

 
of (x) the Landlord’s calculation of Expenses for the year in question, as submitted to the Tenant, or (y) the Tenant’s calculation of
Expenses for the applicable year, as determined by its audit, is closer to the arbitrator’s determination of Expenses allocable to the Premises for the applicable year, and whichever of the Landlord’s calculation or the Tenant’s
calculation is determined by the arbitrator to be closest to the arbitrator’s determination shall be binding upon Landlord and Tenant. The party who does not prevail in such arbitration shall be responsible for all arbitration fees and the
reasonable out-of-pocket attorneys fees and costs of the prevailing party incurred in connection with such arbitration. 
 5. CONDITION OF PREMISES. 

 Landlord shall within a reasonable period of time after receipt of written notice from Tenant, repair, at Landlord’s sole cost and
expense (which shall not be included in Expenses), any latent defects in the Building or the Premises discovered during the Term. 
 6. USE AND OCCUPANCY.

  

	6.1	Use of the Premises. 

 (a) Tenant
agrees to use and occupy the Premises only for the Use described in Section 1.1(g), or for such other purpose as Landlord expressly authorizes in writing. 
 (b) The use of the Premises permitted under Section 6.1(a) shall not include, and neither Landlord nor Tenant shall use, or permit
the use of, the Premises or the Building or any part thereof for: (i) the offices or business of a governmental or quasi governmental bureau, department or agency, foreign or domestic, which is generally open to the public for transaction of
business with the public at the Building; or (ii) conduct or maintenance of any gambling or gaming activities in the Building. 
  

	6.2	Compliance. 

 (a) Tenant agrees to
use the Premises in a safe, careful and proper manner, and to comply with all Laws applicable to Tenant’s use and occupancy of the Premises. If, (i) due to the nature or manner of any use or occupancy of the Premises by Tenant in violation
of the terms of this Lease, or (ii) due to a condition created by Tenant, or a breach of Tenant’s obligations hereunder or the negligence of Tenant or its invitees, any improvements or alterations to the Premises or Building are required
in excess of those required to be provided by Landlord in accordance with the terms of the Lease or changes in the services provided by Landlord according to Section 7 are required to comply with any Laws, or with requirements of
Landlord’s insurers, then Tenant will pay all costs of the required improvements, alterations or changes in services. 
 (b) Landlord represents and warrants to Tenant and its Affiliates (as defined in Section 13.1), that Landlord has not at any time used, and, without independent inquiry, Landlord is not actually aware of the use of any Hazardous
Substances (as 

  

 16 

 
defined below) in or about the Building or the Land in violation of applicable Laws, and, without independent inquiry, Landlord is not actually aware of any
known asbestos, PCBs, underground storage tanks or other Hazardous Substances (defined below) on the Land or in the Building, and Landlord is not actually aware of any violations of applicable Laws relating to Hazardous Substances with respect to
the Building or Land. Landlord and Tenant agree that, during the Term, each will comply, with all Laws governing, and all procedures reasonably established by Landlord for, the use, abatement, removal, storage, disposal or transport of any
substances, chemicals or materials declared to be, or regulated as, hazardous or toxic under any applicable Laws (“Hazardous Substances”) and any required or permitted alteration, repair, maintenance, restoration, removal or
other work in or about the Premises, Building or Land that involves or affects any Hazardous Substances. For the purposes of this Lease, the term Hazardous Substances excludes substances of a type and in a quantity normally used in connection with
the occupancy or operation of office buildings (such as cleaning fluids and supplies normally used in the day to day operation of office establishments), which substances are being held, stored, and used in strict compliance with federal, state, and
local Laws. Each party will indemnify, defend and hold the other and the other’s Affiliates (as defined in Section 13.1) from and against any and all claims, costs and liabilities (including reasonable attorneys’ fees) arising out of
or in connection with any breach by such party of its representations, warranties and covenants under this Section 6.2(b). The parties’ obligations under this Section 6.2(b) will survive the expiration or early termination of the
Term. 
 (c) As of the Date and throughout the Term, Landlord shall be responsible for placing and keeping all portions of the
Project (other than the Premises, except as expressly provided below), including the Building, the Common Areas, Parking Facilities, and all Building systems, in compliance with the provisions of the 1990 Clean Air Act, the Americans with
Disabilities Act (Public Law 10-336, July 26, 1990 (the “ADA”)), any state Laws regarding handicap access or architectural barriers, and all other Laws, to the extent interpreted and enforced from time to time, and
shall be responsible for, undertake all construction, architectural and engineering charges in connection will, and make (or cause to be made) all alterations, additions, improvements and/or renovations to the Building, Common Areas (including
Parking Facilities), and paths of travel such that the same will be in compliance with all such Laws (including the ADA), to the extent interpreted and enforced from time to time. 
 (d) As of the Date and throughout the Term, Landlord shall be responsible for placing and keeping the following areas and items on the
floors on which the Premises is located, whether or not Tenant is or will be the sole occupant of such floors, in compliance with all such Laws referred to in Section 6.2(c) above, to the extent interpreted and enforced from time to time: core
restrooms, drinking fountains existing as of the Date on the floors on which the Premises is located or installed in connection with the initial Tenant Improvements (thus excluding additional drinking fountains installed in the Premises after
installation of the initial Tenant Improvements), fire alarm systems (including strobe lights), exit signs and elevator lobbies, and Landlord shall be responsible for, undertake all construction, architectural and engineering charges in 

  

 17 

 
connection with, and make (or cause to be made), all alterations, additions, improvements and/or renovations, to all such areas and items, such that the same
are in compliance with all such Laws referred to in Section 6.2(c) above, to the extent interpreted and enforced from time to time. 
 (e) Tenant, at its sole cost and expense, shall comply during the Term with such Laws, to the extent interpreted and enforced from time to time, as they relate to the Premises (except for those areas or items
enumerated as Landlord’s responsibility in Section 6.2(d) and/or Exhibit F). Tenant agrees that in the event it provides any plans or specifications for improvements, alterations or additions to the Premises pursuant to the
terms and conditions of this Lease, Tenant shall be obligated to cause such plans to conform to all then applicable requirements of the ADA as interpreted or enforced from time to time and shall otherwise cause them to be in accordance with the
agreements contained in this Section 6.2(e) and Tenant shall notify Landlord of any particular requirements that Tenant may have to enable Landlord to meet its obligations under Sections 6.2(c) and 6.2(d). 
 (f) Landlord and Tenant covenant and agree to reimburse, indemnify, and defend each other for any expenses incurred by the indemnified
party due to the indemnifying party’s failure to conform to the requirements of the ADA as agreed to in Section 6.2(c), 6.2(d) or 6.2(e), including, but not limited to, the cost of making any alterations, renovations or accommodations
required by the ADA, or any governmental enforcement agency, or any court, any and all fines, civil penalties and damages awarded resulting from a violation of the ADA and all reasonable legal expenses incurred in defending such claims made under
the ADA or in enforcing this indemnification; including, but not limited to, reasonable attorney’s fees. Such indemnification shall survive the expiration or termination of this Lease. 
  

	6.3	Occupancy. 

 Tenant will not do or permit anything
to be done which obstructs or interferes with other tenants’ rights or with Landlord’s providing Building services, or which injures other tenants. Tenant will not cause, maintain or permit any nuisance in or about the Premises and will
keep the Premises free of debris, and anything of a dangerous, noxious, toxic or offensive nature or which could create a fire hazard or undue vibration, heat or noise. If any item of equipment, building material or other property brought into the
Building by Tenant or on Tenant’s request causes a dangerous, noxious, toxic or offensive effect (including an environmental effect) and in Landlord’s reasonable opinion such effect will not be permanent but will only be temporary and is
able to be eliminated, then Tenant will not be required to remove such item, provided that Tenant promptly and diligently causes such effect to be eliminated, pays for all costs of elimination and indemnifies Landlord against all liabilities arising
from such effect. Tenant will not make or permit any use of the Premises in violation of the terms of this Lease that may jeopardize any insurance coverage, increase the cost of insurance, require additional insurance coverage, or preclude Landlord
from obtaining insurance. If Tenant fails to comply with the provisions of this Section 6.3 and Tenant has received thirty (30) days prior written 

  

 18 

 
notice of such non-compliance and has failed to remedy such non-compliance and, as a result thereof, Landlord’s insurance premiums are increased, then
Landlord may require Tenant to immediately pay Landlord as Rent the amount of the increase in insurance premiums. 
  

	6.4	Use of Other Portions of the Project. 

 (a) As provided in Section 2.1, Tenant shall have (i) the non-exclusive right to use the Common Areas and the Parking Facilities, (ii) the non-exclusive right to the use plenums, risers, electric closets, ducts, shafts,
flues, conduits and pipes within the Building and the Project but only to the extent that the proposed use is the use intended for such facilities or such facilities can accommodate such proposed use without interfering with the use thereof by
Landlord or any other tenant or proposed tenant for the use for which such facilities were intended, and provided that such use may not exceed Tenant’s Share (unless otherwise agreed by Landlord), (iii) the non-exclusive right to use the
indoor landscaped courtyard area for employee recreation, and (iv) the non-exclusive right to use the outdoor employee barbeque and recreation area. Tenant’s use of the area referenced in (iv) above may include use for food
preparation, setting up tables and chairs, and operation of sound systems for the playing of music and the like; provided, however, any such use shall not unreasonably interfere with other tenants. Tenant shall be responsible for the cleaning any
portion of the outdoor barbeque and recreation area, or the Project, resulting from Tenant’s use of the barbeque and recreation area, but excluding regular cleaning and maintenance of the type commonly performed by Landlord in the exterior
Common Areas, which cleaning and maintenance Landlord shall also perform in the barbeque and recreation area. Tenant shall also have the non-exclusive right to use a portion of the east side parking lot for periodic car wash functions; provided,
however, that any such use shall not unreasonably interfere with the use of such parking facilities by other tenants for parking. 
 (b) Landlord shall provide Tenant with reasonable advance notice of Landlord, any tenant, or any contractor of either of them, entering the plenum space above any floor forming part of the Premises and shall require that any such tenant or
contractor have liability insurance in an amount of not less than $1,000,000 per occurrence. Landlord shall not place or install, and shall not permit any other tenant to place or install, any plumbing lines, fixtures or equipment (other than
straight runs of water piping) in the plenum space above any areas of the Premises reasonably identified in writing by Tenant either in the plans relating to the initial Tenant Improvements, or thereafter, as data room or other sensitive areas;
provided, however, Tenant shall not so identify unreasonably large areas so as to cause undue burden or expense in Landlord’s operation, maintenance, repairs and leasing of the Building, and Landlord shall not be required to remove or modify
any such lines, fixtures or equipment existing in such space prior to such designation by Tenant nor shall Landlord be required to remove or modify any such items in existence in such space as of the Date. Notwithstanding anything to the contrary in
this Lease, subject to Sections 24 and 26.6, Landlord shall indemnify, defend and hold Tenant harmless from and against any and all liability, loss, claims, demand, damages or expenses (including reasonable attorneys’ fees) due to or arising
out of any 

  

 19 

 
accident or occurrence in the plenum space (including, without limitation, accidents, occurrences resulting in injury, death, property damage or theft) to
the extent caused by the willful misconduct or active negligent act or omission by Landlord or Landlord’s agents or contractors. Landlord’s indemnity obligation under this Section 6.4 shall survive the expiration or early termination
of this Lease. 
  

	6.5	Use of Building Stairwells. 

 Tenant may have
non-exclusive use of the Building’s stairways and stairwells for travel between floors constituting the Premises and for emergency exits. 
  

	6.6	Card Key and Other Access Devices. 

 (a) Tenant may install a card key access system in the Premises, in locations to be reasonably agreed by Landlord and Tenant. If Tenant elects to install a card key access system, then Tenant shall install and maintain the card key access
system and related wiring at its sole expense. Prior to installation, Landlord shall have the right to approve the specifications of the system, which approval shall not be unreasonably withheld, conditioned, or delayed. Prior to installation,
Tenant shall submit to Landlord and obtain Landlord’s approval of plans and specifications for the installation and such other information reasonably required by Landlord (which approval shall not be unreasonably withheld, conditioned or
delayed). The installation shall be completed in a workmanlike manner and in accordance with all applicable Laws. Unless requested not to do so by Landlord, at the termination of this Lease (whether upon the Expiration Date or otherwise) Tenant
shall, at Tenant’s sole cost and expense, remove the card key access system and restore the Premises to the condition it was prior to installation, reasonable wear and tear and damage due to fire or other casualty excepted. 
 (b) Landlord shall provide card key access to the Building. 
 7. SERVICES AND UTILITIES. 
  

	7.1	Landlord’s Standard Services. 

 Commencing on
the Date and through the end of the Term, Landlord will operate and maintain the Building (including those portions of the Premises for which Landlord is responsible under Section 6.2 but excluding the remainder of the Premises) in compliance
with all applicable Laws and according to those standards from time to time prevailing for office buildings of similar age, quality and type in the Pleasanton area, or as otherwise specified herein, and Landlord will provide the following services
according to such standards or as otherwise specified herein, the costs of which will, subject to Exhibit F, be included in Expenses to the extent provided in the definition of Expenses set forth in Section 1.2: 
 (a) repair, maintenance and replacement of (i) all the exterior and structural elements of the Building, including the roof
structure, floor slabs, foundation, structural 

  

 20 

 
walls, and exterior windows (ii) the Common Areas, (iii) the exterior landscaping for the Project, (iv) the electrical transformer and all
underground utilities (including sewer and water mains), (v) all general mechanical, HVAC, plumbing, electrical (up to and including the distribution panel) and other systems installed in the Building, excluding, however, Exclusive Systems,
(vi) core restrooms; and (vi) all damage to the Premises attributable to Landlord’s active negligence or willful misconduct or the active negligence or willful misconduct of Landlord’s agents, contractors and/or employees;

 (b) heating, ventilating and air conditioning of the Premises during Building Business Hours and, to the extent required by
Tenant pursuant to Section 7.2(a) below, outside of Building Business Hours, and heating, ventilating and air conditioning of the Common Areas of the Building during Building Business Hours, for comfortable occupancy during Normal Business
Hours assuming an occupancy density not greater than one person per 200 rentable square feet, for any given room or area within the Premises, and subject at all times, however, to restrictions placed upon Landlord by any duly constituted
governmental agency and/or by any duly constituted governmental agency and/or by any utility supplier; 
 (c) hot and cold
water for the restrooms and water for drinking fountains; 
 (d) electrical facilities sufficient to permit the electrical
service provider for the Project to provide up to six (6) watts per square foot of connected load per Rentable Square Foot in the Premises; 
 (e) janitorial services to the Common Areas of the Project, exclusive of Holidays and weekends; 
 (f) two passenger elevators during Building Business Hours and at least one (1) passenger elevator 24 hours a day, seven (7) days a week for access to and from the floor(s) on which the Premises are located; 
 (g) core restroom facilities on each floor on which the Premises is located; including necessary restroom supplies for any Common Area
restroom facilities on multi-tenant floors (i.e., floors on which the Premises is not the only rentable space) sufficient for a typical office tenant’s normal use; 
 (h) electric lighting for all Common Areas that require electric light during the day or are open at night, including replacement of tubes
and ballasts in lighting fixtures; and 
 (i) replacement of tubes and ballasts in lighting fixtures installed in the
Premises. 
  

	7.2	Off-Hours HVAC; Supplemental HVAC. 

 (a) Tenant shall have the right to use the base building HVAC system to 

  

 21 

 
provide HVAC for the Premises outside of Building Business Hours by arranging such service through Landlord in advance. Tenant shall have the right, at its
sole cost, if possible, to install a mechanism to be able to activate the HVAC after hours so that Tenant would not need to arrange such service through Landlord in advance. Tenant shall reimburse Landlord at the then rate being charged by Landlord
in the Building for HVAC service provided outside of Building Business Hours (which shall not be less than $40 per hour per floor). 
 (b) Tenant shall have the right, subject to Section 9.1, to install supplemental air conditioning units to serve the Premises as Tenant deems reasonably necessary or desirable; provided, however, Tenant shall not install such units if
the same may, in Landlord’s reasonable judgment, cause a substantial risk of overload of the utilities systems serving the Building for both present and future users. Notwithstanding Tenant’s installation of any supplemental air
conditioning units, Landlord shall continue to supply HVAC to the entire Premises. 
  

	7.3	Electrical for the Project and Janitorial Services to the Premises. 

 (a) Electrical consumption for space within the Project is not separately metered. As such, Tenant shall pay to Landlord, from and after
the Rent Commencement Date, monthly, within twenty (20) days after Tenant’s receipt of a written invoice therefore, Tenant’s Electrical Share of such utility charges. Landlord shall have the right to install at Landlord’s
expense, separate meters and/or separate subpanels so as to permit the electrical consumption of Tenant to be separately metered, in which case the costs of such electrical consumption shall be paid by Tenant based on its actual consumption, with
the costs of all electrical consumption relating to the Common Areas allocated to Tenant based on ratio of the number of Rentable Square Feet in Tenant’s space to the total number of Rentable Square Feet in the Building. In addition, Tenant, at
its option, may install or require Landlord to install, at Tenant’s expense (which expense shall be subject to Tenant’s prior approval), separate meters and/or separate subpanels so as to permit the electrical consumption of Tenant to be
separately metered, in which case the costs of such electrical consumption shall be paid by Tenant based on its actual consumption, with the costs of all electrical consumption relating to the Common Areas allocated to Tenant based on ratio of the
number of Rentable Square Feet in Tenant’s space to the total number of Rentable Square Feet in the Building. 
 (b)
Tenant shall be responsible for obtaining its own janitorial services for the Premises, including all supplies necessary to perform such janitorial services. 
  

	7.4	Interruption of Services. 

 (a) If
any of the services provided for in this Section 7, or Tenant’s access to the Premises, are interrupted or stopped, Landlord will promptly use (i) best efforts to resume the service or access to the extent the same is within the
reasonable control of Landlord and (ii) all commercially reasonable due diligence to cause others to resume the service or access to the extent the same is beyond the reasonable control of Landlord; 

  

 22 

 
provided, however, no irregularity or stoppage of any of these services or access will (A) create any liability for Landlord (including, without
limitation, any liability for damages to Tenant’s personal property caused by any such irregularity or stoppage), unless due to Landlord’s active negligence or willful misconduct, (B) constitute an actual or constructive eviction,
(C) except as expressly set forth herein, cause any abatement of the Rent payable under this Lease or (D) in any manner or for any purpose relieve Tenant from any of its obligations under this Lease. 
 (b) If any of the services required to be provided by Landlord under this Section 7, the restoration of which service is within
Landlord’s reasonable control, should become unavailable and should remain unavailable for a period in excess of seventy two (72) consecutive hours after notice of such unavailability from Tenant to Landlord), and if such unavailability
should render Tenant unable to reasonably use any or all of the Premises for the conduct of its business in substantially the same manner as prior to such interruption or stoppage (“Untenantable”), then commencing upon the
expiration of such time period, Tenant’s Rent will equitably abate in proportion to the portion of the Premises so rendered Untenantable for so long as such services remain unavailable for such reasons. For purposes of this Lease, a portion of
the Premises that would otherwise be Untenantable if Tenant did not elect to use any available UPS system, emergency generator or supplemental HVAC equipment (“Back-Up Equipment”) shall be deemed Untenantable even if Tenant
continues to use such portion of the Premises if Tenant’s continued use is due to Tenant’s election to utilize the service provided by such Back-Up Equipment. Tenant shall have no obligation to use Tenant’s Back-Up Equipment at any
time, and any election by Tenant not to use such Back-Up Equipment at any time shall not reduce any abatement of Rent to which Tenant entitled under this Section 7.4(b). 
 (c) If any Critical Service (defined below) required to be provided by Landlord
under this Section 7 or Tenant’s continued access to the Premises should become unavailable and should remain unavailable for a period in excess of ninety (90) days after notice of such unavailability from Tenant to Landlord, and if
such unavailability should render at least fifty percent (50%) of the Premises Untenantable, then Tenant shall have the option to terminate this Lease in its entirety effective as of the date thirty (30) days after the date Tenant gives
written notice to Landlord of Tenant’s exercise of such termination option, which notice may be given by Tenant at any time after the first sixty (60) days of the unavailability of service or access; however, notwithstanding any
termination notice given hereunder, this Lease shall not terminate if the unavailable service or access is restored prior to the thirtieth (30th) day following Tenant’s termination notice. 
 (d) Tenant hereby waives the provisions of Sections 1932,
1933(4) and 1942 of the Civil Code of California or any similar or successor statutes to the fullest extent permitted by Law, and Tenant acknowledges that, except as specifically provided herein, in the event Landlord fails to make a repair or
perform maintenance, Tenant’s sole remedy for such breach by Landlord shall be an action for damages, and that Tenant shall not be entitled to terminate this Lease, withhold rent, or make any repair and deduct the cost of repair from rent
payable under this Lease. 
  

 23 

	7.5	Self-Help Right for Failure to Deliver Services; Right to Replace Property Manager. 

 If at any time during the Term (i) Landlord fails to deliver electrical service, HVAC service, sewer service, water service, or elevator service to
the Premises (each, a “Critical Service”) or (ii) the life-safety systems for the Premises or the Building are not operational or (iii) Tenant’s continued access to the Premises is interrupted, in any case for
five (5) consecutive business days after Tenant advises Landlord in writing that such Critical Service or access is not being provided or the life-safety systems are not operational, and (iv) Landlord has not commenced to cure the same
with such five-day period or has failed to prosecute such cure with reasonable diligence, then Tenant shall be entitled (A) to take reasonable steps, based on the exercise of Tenant’s good-faith judgment under the circumstances, to restore
the Critical Service, access or life-safety systems, as applicable and (B) to offset the Self Help Costs (defined below) against future Rent becoming due under this Lease. “Self Help Costs” means all third-party,
out-of-pocket expenses incurred (based on the exercise of Tenant’s good-faith judgment) by Tenant or Tenant’s agents or contractors in connection with restoring the Critical Service, access or life-safety systems, as applicable.

 8. TENANT REPAIRS. 
  

	8.1	Repairs Within the Premises. 

 Subject to the terms
of Sections 6, 7.1(a), 12 and 14, and except to the extent Landlord is required or elects to perform or pay for certain maintenance or repairs according to those sections, Tenant will, at Tenant’s own expense: (a) at all times during the
Term, maintain the Premises, all fixtures and equipment in the Premises and Exclusive Systems in good order and repair and in a condition that complies with all applicable Laws; and (b) promptly and adequately repair all damage to the Premises
and replace or repair all of such fixtures, equipment and any Exclusive Systems that are damaged or broken, all under the supervision and subject to the prior reasonable approval of Landlord. All work done by Tenant or its contractors (which
contractors will be subject to Landlord’s reasonable approval) will be done in a first-class workmanlike manner using only grades of materials at least equal in quality to Building Standard materials and will comply with all insurance
requirements and all applicable Laws. Tenant shall not place any object or series of objects on the floors of the Premises in such a manner as to exceed the load capacity of the floors on a per square foot basis as reasonably determined by any
architect, engineer, or other consultant of Landlord, or as otherwise limited by any applicable Laws. 
  

	8.2	Failure to Maintain Premises. 

 If Tenant fails to
perform any of its obligations under Section 8.1, then without limiting any other remedies of Landlord, following fifteen (15) days advance written notice Landlord, if such repairs have not been completed, may perform such obligations and
Tenant will pay as Rent to Landlord the cost of such performance within thirty (30) days 

  

 24 

 
after the date of Landlord’s invoice in an amount not to exceed Landlord’s reasonable actual out-of-pocket costs. For purpose of performing such
obligations, or to inspect the Premises, Landlord may enter the Premises upon not less than one (1) day’s prior notice to Tenant (except in cases of actual or suspected emergency, in which case no prior notice will be required) without
liability to Tenant for any loss or damage incurred as a result of such entry, provided that Landlord will take reasonable steps in connection with such entry to minimize any disruption to Tenant’s business or its use of the Premises and
Landlord shall be responsible for any loss or damage due to Landlord’s gross negligence of willful misconduct. Entry by Landlord to pursue repair, maintenance, or correction shall not be deemed an actual or constructive eviction and shall not
entitle Tenant to any abatement or reduction in Rent. 
  

	8.3	Notice of Damage. 

 Landlord or Tenant will notify
the other party promptly after it learns of (a) any damage to or defect in the Premises, including the fixtures and equipment in the Premises, for the repair of which the other party might be responsible; and (b) any damage to or defect in
any parts of appurtenances of the Building’s sanitary, electrical, heating, air conditioning, elevator or other systems located in or passing through the Premises. 
 9. ALTERATIONS. 
  

	9.1	Alterations by Tenant. 

 (a) Tenant
may from time to time at its own expense make changes, additions and improvements to the Premises (individually or collectively referred to as “Alterations”), provided that any such Alterations (i) will comply with all
applicable Laws; (ii) will be made only with the prior written consent of Landlord, which consent will not be unreasonably withheld, conditioned or delayed; (iii) will be carried out only by persons selected by Tenant and approved in
writing by Landlord, such approval not to be unreasonably withheld, conditioned or delayed; (iv) do not materially adversely affect the integrity of the Building’s structure or exceed or materially adversely affect the capacity,
maintenance, or operating cost of the Building’s HVAC, plumbing, mechanical, electrical, life safety, communications or other systems; (v) if required, is approved by the holder of any Encumbrance; and (vi) does not alter the
appearance of the exterior of the Building in any material way. 
 (b) Notwithstanding the foregoing, Tenant shall not be
required to obtain Landlord’s prior consent (but Tenant will provide to Landlord five (5) days prior written notice, together with copies of any related plans that are in fact prepared and all necessary permits required by applicable Law)
(i) for repainting, or installing or removing floor coverings or wall coverings, regardless of the total cost with respect thereto, or (ii) for other tenant improvements, alterations or physical additions to the Premises that total less
than Fifty Thousand and No/100 Dollars ($50,000) in any single instance, so long as the installation thereof does not materially adversely affect the Building’s structure, or materially adversely affect the Building’s electrical, plumbing,
HVAC, life safety or mechanical systems or the exterior appearance of the Building. 
  

 25 

 (c) If Landlord consent is required with respect to any Alterations proposed by Tenant,
Landlord shall notify Tenant in writing of Landlord’s consent to or disapproval of the proposed Alterations within ten (10) days after receipt of Tenant’s request for consent. If Landlord notifies Tenant that Landlord disapproves of
the proposed Alterations, Landlord’s notice shall include a detailed explanation of the reasons for such disapproval, which shall be limited to those set forth in Section 9.1(a). In the event Landlord fails to so notify Tenant within such
ten (10) day period, Landlord shall be deemed to have given its consent to the proposed Alterations. If requested by Tenant in writing at the time Tenant requests Landlord’s approval for an Alteration, Landlord shall notify Tenant at the
time Landlord responds to Tenant’s request whether Landlord will require Tenant to remove the proposed Alterations at the expiration or earlier termination of the Term. In addition, in connection with any proposed Alterations as to which
Landlord’s consent is not required hereunder, Landlord shall, if Tenant so requests, notify Tenant in writing, within ten (10) days after Tenant’s request (so long as such request contains a reasonable description of such
Alterations), whether Landlord will require Tenant to remove all or part of the proposed Alterations at the expiration or earlier termination of the Term. 
 (d) For any alterations, Tenant shall provide Landlord at least five (5) days written notice before any work is commenced, which notice shall state the date work shall commence. Tenant will maintain, or will
cause the persons performing any such work to maintain, worker’s compensation insurance and public liability and property damage insurance (with Landlord named as an additional insured), in amounts, with companies and in a form reasonably
satisfactory to Landlord, which insurance will remain in effect during the entire period in which the work will be carried out. If requested by Landlord, Tenant will deliver to Landlord proof of all such insurance. Tenant will promptly pay, when
due, the cost of all such work and, upon completion, Tenant will deliver to Landlord, to the extent not previously received by Landlord, evidence of payment for labor, services or materials. Tenant will also pay any increases in fire or casualty
insurance premiums for the Building attributable to such Alterations and the cost of any modifications to the Building outside the Premises that are required to be made in order to make the Alterations to the Premises. Tenant, at its expense, will
have submitted to Landlord reproducible as-built plans of any such Alterations upon its completion. 
  

	9.2	Alterations and Entry by Landlord. 

 (a) Landlord may from time to time make repairs, changes, additions and improvements to the Building, Common Areas and Building systems, provided that no change, addition or improvement made by Landlord will materially impair Tenant’s
use of, or access to the Premises. For such purposes, Landlord may enter the Premises upon not less than one (1) days’ prior written notice to Tenant (except in cases of actual or reasonably suspected emergency, in which case no prior
notice will be required) without liability to Tenant for any loss or damage incurred as a result of such entry, provided that 

  

 26 

 
in doing so Landlord will not disturb or interfere with Tenant’s use of the Premises and operation of its business any more than is reasonably necessary
under the circumstances and will repair any damage to the Premises caused by such entry and Landlord shall be responsible for any loss or damage due to Landlord’s active negligence or willful misconduct. Entry by Landlord to pursue repair,
maintenance, or correction shall not be deemed an actual or constructive eviction and shall not entitle Tenant to any abatement of reduction in Rent. 
 (b) Landlord and its agents, employees and contractors shall also have the right to enter the Premises during Tenant’s normal business hours upon not less than twenty four (24) hours prior notice, without
undue interference with the conduct of Tenant’s business therein, to inspect and examine the Premises and to exhibit the Premises to prospective purchasers or prospective tenants of the Project, and Landlord shall allow a representative of
Tenant to accompany Landlord, its agents, employees and/or contractors if so requested by Tenant. 
  

	9.3	Project Management; No Review, Supervisory, Profit or Overhead Charges. 

 Subject to Landlord approval thereof, which approval shall not be unreasonably withheld, delayed or conditioned, Tenant may engage its own project managers, architects, engineers, consultants, general contractors and
subcontractors in connection with any repairs or any improvements, alterations, additions, renovations or refurbishments to be performed by Tenant hereunder. Notwithstanding any provision of this Lease to the contrary, no review fees of Landlord or
any third party relating to the design or performance of any such repairs, improvements, alterations, additions, renovations or refurbishments shall be charged to Tenant and no Landlord profit, overhead, or supervision fee, or general conditions
costs shall be charged to Tenant with respect to any repairs or any improvements, alterations, additions, renovations or refurbishments, whether such work shall be undertaken by Landlord (or Landlord’s contractor) or Tenant (or Tenant’s
contractor). 
 10. LIENS. 
 Tenant agrees
to pay before delinquency all costs for work, services or materials furnished to Tenant for the Premises, the nonpayment of which could result in any lien against the Land or Building. Tenant will keep title to the Land and Building free and clear
of any such lien. Tenant will immediately notify Landlord of the filing of any such lien or any pending claims or proceedings relating to any such lien and will indemnify, defend and hold Landlord harmless from and against all loss, damages and
expenses (including reasonable attorneys’ fees) suffered or incurred by Landlord as a result of such lien, claims and proceedings. In case any such lien attaches, Tenant agrees to cause it to be immediately released and removed of record
(failing which Landlord may do so at Tenant’s sole expense), unless Tenant has a good faith dispute as to such lien in which case Tenant may contest such lien by appropriate proceedings so long as Tenant deposits a lien release bond (if
applicable) drawn on a bondsman acceptable to Landlord or deposits with Landlord a bond or other security in an amount reasonably acceptable to 

  

 27 

 
Landlord which may be used by Landlord to release such lien. Upon final determination of any permitted contest, Tenant will immediately pay any judgment
rendered and cause the lien to be released. 
 11. INSURANCE. 
  

	11.1	Landlord’s Insurance. 

 During the Term,
Landlord will provide and keep in force the following insurance: 
 (a) commercial general liability insurance relating to
Landlord’s operation of the Building, for personal and bodily injury and death, and damage to others’ property; and 
 (b) all risk or fire insurance (including standard extended coverage endorsement perils, leakage from fire protective devices and other water damage, and other commercial reasonable coverage customarily carried by landlords of similar class
buildings as Landlord may elect to cover) relating to the Land and Building (but excluding Tenant’s leasehold improvements, trade fixtures, furnishings, equipment, personal property, documents, files, inventory, stock-in-trade and work
products), on a full replacement cost basis. 
 (c) Insurance effected by Landlord under this Section 11.1 will be in
amounts which Landlord from time to time reasonably determines sufficient or any Building mortgagee requires except that the coverage under Section 11.1(b) shall provide full replacement cost coverage; (ii) will be subject to such
deductibles and exclusions as Landlord reasonably determines; (iii) will, in the case of insurance under Sections 11.1(b), permit the release of Tenant from certain liability under Section 13.1; and (iv) will otherwise be on such
terms and conditions as Landlord from time to time reasonably determines sufficient. 
  

	11.2	Tenant’s Insurance. 

 During the Term, Tenant
will provide and keep in force the following insurance: 
 (a) commercial general liability insurance relating to
Tenant’s business (carried on in or from the Premises) and Tenant’s use and occupancy, for personal and bodily injury and death, and damage to others’ property, with limits of not less than the Liability Insurance Amount for any one
accident or occurrence; 
 (b) all risk or fire insurance (including standard extended endorsement perils, leakage from fire
protective devices and other water damage, but excluding coverage for earthquake or earth movement) relating to Tenant’s leasehold improvements, trade fixtures, furnishings, equipment, documents, files, work products, inventory, stock-intrade
in the Premises on a full replacement cost basis; 
  

 28 

 (c) if any boiler or machinery is operated in the Premises, boiler and machinery
insurance; and 
 (d) workers compensation insurance as required by law. 
 Landlord and the holder of any Encumbrance will be named as an additional insureds in the policy described in Section 11.2(a), which will include
cross liability and severability of interests clauses and will be on an “occurrence” (and not a “claims made”) form. Tenant will file with Landlord, on or before the Rent Commencement Date and at least ten (10) days before
the expiration date of expiring policies, such copies of either current policies, an insurance binder (countersigned by the insurer), evidence of insurance, a binding certificate or other proofs, as may be reasonably required to establish
Tenant’s insurance coverage in effect from time to time and payment of premiums. If Tenant fails to insure or pay premiums, or to file satisfactory proof as required, Landlord may, upon a minimum of two business days notice, effect such
insurance and recover from Tenant on demand any premiums paid. 
 Notwithstanding the foregoing, Tenant may carry any insurance required to be
carried by Tenant under this Lease by Tenant in whole or in part under an umbrella policy or policies, or under a blanket policy or policies, covering other properties. 
 12. DAMAGE OR DESTRUCTION. 
  

	12.1	Damage Notice; Repair Estimate. 

 If the Premises or
the Building are damaged by fire or other casualty, Landlord or Tenant, whichever learns of such damage first, will promptly notify the other party of such damage. Landlord will, promptly after learning of such damage, notify Tenant in writing (the
“Repair Estimate”) of the estimated time and cost necessary to repair or restore such damage, as estimated by a licensed architect, engineer or contractor selected by Landlord and approved by Tenant. 
  

	12.2	Termination Options. 

 (a)
Tenant’s Termination Options. If (i) the Repair Estimate states that damage to the Building (measured by the estimated cost of repair or restoration) is fifty percent (50%) or more of the Building’s then replacement cost
above the foundation as indicated in the Repair Estimate, (ii) the Repair Estimate states that the repair or restoration of all such damage to the Building cannot be completed, through the use of commercially reasonable diligence in the
preparation of plans, obtaining of permits and construction, within eighteen (18) months from the date of such damage, (iii) more than thirty-five percent (35%) of the Rentable Square Feet then included in the Premises is rendered
Untenantable and any material portion of the Premises will likely remain Untenantable for more than nine (9) months after the date of the casualty, or (iv) the Repair Estimate states that repair or restoration of all such damage that was
caused to the Premises or to any other portion of the Building necessary for Tenant’s occupancy cannot 

  

 29 

 
be completed within ninety (90) days from the date of such damage and less than twelve (12) months are then remaining in the Term, then Tenant
shall have the right to terminate this Lease. 
 (b) Landlord’s Termination Options. If (i) the Repair
Estimate states that damage to the Building (measured by the estimated cost of repair or restoration) is fifty percent (50%) or more of the Building’s then replacement cost above the foundation as indicated in the Repair Estimate, or
(ii) the Repair Estimate states that the repair or restoration of all such damage to the Building cannot be completed, through the use of commercially reasonable diligence in the preparation of plans, obtaining of permits and construction,
within eighteen (18) months from the date of such damage, or (iii) the Repair Estimate states that repair or restoration of all such damage that was caused to the Premises or to any other portion of the Building necessary for Tenant’s
occupancy cannot be completed within ninety (90) days from the date of such damage and less than twelve (12) months are then remaining in the Term and Tenant fails to exercise its Extension Option within fifteen (15) days after
Landlord delivers the Repair Estimate, then Landlord shall have the right to terminate this Lease; provided, however, that Landlord shall only be able to terminate this Lease if Landlord also terminates the leases of all other tenants in the
Building which are similarly affected by such casualty and as to which Landlord has the right to terminate such leases. 
 (c)
Exercise of Options. Any option to terminate granted above must be exercised by written notice to the other party given within fifteen (15) days after Landlord delivers to Tenant the Repair Estimate. If either party exercises its option
to terminate this Lease, the Term will expire and this Lease will terminate thirty (30) days after notice of termination is delivered; provided, however, that notwithstanding the delivery of any such termination notice, in order to provide an
orderly transition to another building, Tenant may elect to continue this Lease as to any portion of the Premises that remains tenantable, for a period of up to four (4) months on a month to month basis, in which event the terms of this Lease
shall continue to apply as to any space continuing to be so occupied, including the payment of Base Rent and Additional Rent with respect to such space and parking rights on the same basis as originally applicable to such portion of the Premises.
Rent for the period commencing on the date of such damage until the date this Lease terminates will be reduced to the reasonable value of any use or occupation of the Premises by Tenant during such period. 
  

	12.3	Repair Obligations. 

 If the Premises or the
Building are damaged by fire or other casualty and neither party (a) has the right to terminate this Lease according to Section 12.2, or (b) terminates this Lease according to Section 12.2, then Landlord will repair and restore
such damage with reasonable promptness, subject to delays for insurance adjustments and delays caused by Force Majeure or delays caused by Tenant. Except as set forth below, Landlord will have no liability to Tenant and Tenant will not be entitled
to terminate this Lease if such repairs and restoration are completed within the estimated time period indicated in the Repair Estimate or within thirty (30) days thereafter; however, if the repairs or restoration 

  

 30 

 
are not completed within thirty (30) days following the end of the estimated time period (subject to Force Majeure and delays caused by Tenant), Tenant
shall have the option to terminate this Lease. In no event will Landlord be obligated to repair, restore or replace any of the property required to be insured by Tenant according to Section 11.2. 
  

	12.4	Rent Abatement. 

 If any fire or casualty damage
renders any portion of the Premises Untenantable, then Rent will abate beginning on the date of such damage. Such abatement will end on the date Landlord has substantially completed the repairs and restoration Landlord is required to perform
according to Section 12.3. Such abatement will be in an amount bearing the same ratio to the total amount of Rent for such period as the Untenantable portion of the Premises bears to the entire Premises. In no event will Landlord be liable for
any inconvenience or annoyance to Tenant or injury to the business of Tenant resulting in any way from damage caused by fire or other casualty or the repair of such damage; provided, however, that to the extent Tenant remains in possession of a
portion of the Premises, Landlord shall take all reasonable steps to minimize unreasonable disruption to Tenant’s business and use of such portion of the Premises during the period of repair, including, to the extent the same can be done
without Landlord incurring material additional costs for overtime labor, performing all noisy work (such as hammering, slab work, nail guns and the like) outside of Building Business Hours. 
 13. WAIVERS AND INDEMNITIES. 
 As used in this Section 13, a
party’s “Affiliates” means each Affiliate of such party and its and their directors, officers, shareholders, agents, servants, employees and, in Tenant’s case, permitted subtenants. 
  

	13.1	Landlord’s Waivers. 

 Notwithstanding anything
in this Lease to the contrary, Tenant and its Affiliates will not be liable or in any way responsible to Landlord for, and Landlord waives all claims against Tenant and its Affiliates to the extent any loss, injury or damage is insured or required
to be insured by Landlord under Section 11.1(b), EXCLUDING ANY DEDUCTIBLE THEREUNDER (NOT TO EXCEED $5,000) REGARDLESS OF WHETHER SUCH LOSS, INJURY OR DAMAGE IS ATTRIBUTABLE IN WHOLE OR IN PART TO THE NEGLIGENCE, GROSS NEGLIGENCE OR WILLFUL
MISCONDUCT OF TENANT OR ANY OF ITS AFFILIATES. Landlord’s waivers under this Section 13.1 will survive the expiration or early termination of the Term. 
  

	13.2	Tenant’s Waivers. 

 Except to the extent caused
by the willful or active negligent act or omission or breach of this Lease by Landlord or anyone for whom Landlord is legally responsible, notwithstanding anything in this Lease to the contrary, Landlord, its Affiliates and the 

  

 31 

 
holder of any Encumbrance will not be liable or in any way responsible for, and Tenant waives all claims against Landlord, its Affiliates and the holder of
any Encumbrance for any loss, injury or damage suffered by Tenant or others relating to (a) loss or theft of, or damage to, property of Tenant or others; (b) injury or damage to persons or property from any cause, including, without
limitation, fire, explosion, falling plaster, escaping steam or gas, electricity, water, rain or snow, or leaks from any part of the Building or from any pipes, appliances or plumbing, or from dampness; or (c) damage caused by other tenants,
occupants or persons in the Premises or other premises in the Building, or caused by the public or by construction of any private or public work. 
 In addition and without limiting the foregoing, Landlord, its Affiliates and the holder of any Encumbrance will not be liable or in any way responsible to Tenant for, and Tenant waives all claims against Landlord, its Affiliates and the
holder of any Encumbrance to the extent any loss, injury or damage is insured or required to be insured by Tenant under Sections 11.2(b) or (c), EXCLUDING ANY DEDUCTIBLE THEREUNDER (NOT TO EXCEED $10,000), REGARDLESS OF WHETHER SUCH LOSS, INJURY
OR DAMAGE IS ATTRIBUTABLE IN WHOLE OR IN PART TO THE NEGLIGENCE, GROSS NEGLIGENCE OR WILLFUL MISCONDUCT OF LANDLORD OR ANY OF ITS AFFILIATES. Tenant’s waivers under this Section 13.2 will survive the expiration or early termination of
the Term. 
  

	13.3	Landlord’s Indemnity. 

 Subject to
Section 7.5 and 13.2 and except to the extent caused by the willful or active negligent act or omission or breach of this Lease by Tenant or anyone for whom Tenant is legally responsible, Landlord will indemnify, defend and hold Tenant harmless
from and against any and all liability, loss, claims, demand, damages or expense (including reasonable attorneys’ fees) for any personal injury or property damage to persons other than Landlord or Tenant due to or arising out of any willful or
active negligent act or omission of Landlord or anyone for whom Landlord is legally responsible. Landlord’s obligations under this Section 13.3 will survive the expiration or early termination of the Term. 
  

	13.4	Tenant’s Indemnity. 

 Subject to Sections 24
and 13.1 and except to the extent caused by the willful or active negligent act or omission or breach of this Lease by Landlord or anyone for whom Landlord is legally responsible, Tenant will indemnify, defend, and hold Landlord and the holder of
any Encumbrance harmless from and against any and all liability, loss, claims, demands, damages or expenses (including reasonable attorneys’ fees) for any personal injury or property damage to persons other than Landlord or Tenant due to or
arising out of any accident or occurrence on or about the Premises or any willful or active negligent act or omission of Tenant or anyone for whom Tenant is legally responsible. Tenant’s obligations under this Section 13.4 will survive the
expiration or early termination of the Term. 
  

 32 

	13.5	Waiver of Subrogation. 

 Each party shall require
its insurers to include in the insurance policies required under Section 11.1(b) and Sections 11.2(b) and (c) a waiver of subrogation clause in favor of the other party and its Affiliates (providing that each party’s waivers of rights
of recovery against the other shall not impair the effectiveness of such policy or the insured’s ability to recover thereunder). 
 14. CONDEMNATION.

  

	14.1	Full Taking. 

 If all or substantially all of the
Building, Parking Facilities or Premises are taken for any public or quasi-public use under any applicable Laws or by right of eminent domain, or are sold to the condemning authority in lieu of condemnation, then this Lease will terminate as of the
date the earlier of when the condemning authority takes physical possession of or title to the Building or Premises. 
  

	14.2	Partial Taking. 

 (a)
Landlord’s Termination of Lease. If ten percent (10%) or more, but less than all, of the Building is thus taken or sold, and if after such partial taking, in Landlord’s reasonable judgment, alteration or reconstruction is not
economically feasible, then Landlord (whether or not the Premises are affected) may terminate this Lease by giving written notice to Tenant within 60 days after the taking. 
 (b) Tenant’s Termination. If over twenty percent (20%) of the Premises or Parking Facilities is taken or sold, or
rendered unusable for its Use, and Landlord is unable to provide Tenant with comparable replacement premises in the Building or parking facilities, as applicable, Tenant may terminate this Lease. Such termination by Tenant must be exercised by
written notice to Landlord given not later than 60 days after Tenant is notified of the taking. 
 (c) Effective Date of
Termination. Termination by Landlord or Tenant will be effective as of the date when physical possession of the applicable portion of the Building or Premises is taken by condemning authority. 
 (d) Election to Continue Lease. If neither Landlord nor Tenant elects to terminate this Lease upon a partial taking of a portion of
the Premises, the Rent payable under this Lease will be diminished by an amount allocable to the portion of the Premises which was so taken or sold or rendered unusable for its Use. In no event shall the loss of any portion of the Land (other than
the portion of the Land on which the Premises are physically located) result in a reduction of Rent. If this Lease is not terminated upon a partial taking of the Building or Premises, Landlord will, at Landlord’s sole expense, promptly restore
and reconstruct the Building and Premises to substantially their former condition to the extent the same is feasible; however, Landlord will not be required to 

  

 33 

 
spend for such restoration or reconstruction an amount in excess of the net amount received by Landlord as compensation or damages for the part of the
Building or Premises so taken. 
  

	14.3	Awards. 

 As between the parties to this Lease,
Landlord will be entitled to receive, and Tenant assigns to Landlord, all of the compensation awarded upon taking of any part or all of the Building or Premises, including any award for the value of the unexpired Term. However, Tenant may assert a
claim in a separate proceeding against the condemning authority for any damages resulting from the taking of Tenant’s trade fixtures or personal property, or for moving expenses, business relocation expenses or damages to Tenant’s business
incurred as a result of such condemnation. Tenant shall not be entitled to any “bonus value” as Landlord shall be the only party entitled to an award that would otherwise cover “bonus value”. 
 15. ASSIGNMENT AND SUBLETTING. 
  

	15.1	General. 

 Except as set forth in this
Section 15, without Landlord’s prior written consent (which consent shall not be unreasonably withheld, conditioned or delayed), Tenant will not assign all or any of its interest under this Lease, or sublet all or any part of the Premises
to any parties other than Tenant and its Affiliates nor shall Tenant permit the Premises to be used by anyone other than Tenant, it Affiliates, and their respective employees and invitees. Landlord shall have fourteen (14) days following
receipt from Tenant of written notice of its intent to assign this Lease or sublease all or a portion of the Premises, including all relevant financial information with respect to the proposed assignee or subtenant reasonably necessary for Landlord
to make such decision, to notify Tenant in writing that it does not consent to a prospective assignee or sublessee. Any such notice shall provide in reasonable detail the reasons for Landlord’s non-consent. The fact that a prospective assignee
or sublessee is an existing tenant in the Building or the complex of which it is a part or a prospect with whom Landlord is or may be negotiating to lease space in the Building or the complex of which it is a part shall not be a reasonable basis
upon which Landlord may withhold its consent. Failure to exercise its election to not consent within such fourteen (14) day period shall be deemed consent by Landlord to the proposed assignee or sublessee. Landlord shall be reimbursed
Landlord’s reasonable out-of-pocket, third party costs and reasonable attorney fees incurred in reviewing any requested assignment or subleasing. 
  

	15.2	Form Of Transfer. 

 If Landlord consents to a
proposed assignment or sublease, Landlord’s consent will not be effective unless and until Tenant delivers to Landlord an original duly executed assignment or sublease, as the case may be, that provides, in the case of a sublease, that the
subtenant will comply with all applicable terms and conditions of this Lease as they 

  

 34 

 
apply to the space subleased, and, in the case of an assignment, an assumption by the assignee of all obligations of Tenant under this Lease arising from and
after the date of such assignment. 
  

	15.3	Payments To Landlord. 

 If Tenant assigns this Lease
or subleases all or a portion of the Premises other than an assignment or subletting pursuant to Section 15.4, then Landlord will be entitled to receive from Tenant fifty percent (50%) of the amount by which (a) the rent (and other
consideration) received by Tenant from such transferee exceeds (b) the sum of the Rent then due for the same period of time under this Lease payable by Tenant to Landlord (and if a sublease, allocable to the subleased space) plus the amortized
portion of any costs and expenses incurred by Tenant in connection with such transfer (including tenant improvement allowances, brokerage commissions, attorneys fees and other customary and reasonable costs) amortized on a straight line basis over
the term of such transfer; provided, however, that Tenant shall be entitled to recoup one hundred percent (100%) of its actual out of pocket tenant improvement allowances as well as it’s customary and reasonable brokerage commissions,
attorneys fees and other costs before paying Landlord any portion of such excess if the rent (and other consideration) received by Tenant from such transferee is paid in a lump sum. Landlord’s percentage of such excess will be payable to
Landlord if and within fifteen (15) days after Tenant is paid the same (whether in monthly installments, in a lump sum, or otherwise). 
  

	15.4	Permitted Transfers. 

 Tenant may, without obtaining
Landlord’s consent, assign this Lease or sublease all or any part of the Premises to (i) any Affiliate, (ii) any entity resulting from the merger or consolidation, liquidation or reorganization of Tenant so long as all or
substantially all of the assets of Tenant located at the Premises were transferred to the resulting entity, or (iii) any entity which acquires all or substantially all of the assets of Tenant located at the Premises as part of the purchase of
the business that is being conducted on or from the Premises; provided that in all such cases such transferee assumes in full the obligations of Tenant under the Lease arising from and after the effective date of the assignment or sublease (but, in
the case of a sublease, only as to the portion of the Premises subleased to such subtenant). In any event described in this Section 15.4, Tenant shall have no obligation to share with Landlord any rent or other consideration received by Tenant
in connection with such assignment or sublease. Tenant shall promptly provide notice to Landlord of any assignment or sublease of the Premises which does not require Landlord’s consent pursuant to this Section 15.4. Tenant shall use good
faith efforts to provide such notice prior to date of such transfer, but shall have no liability for failing to do so. 
  

	15.5	Effect Of Transfers. 

 Except as provided in
Section 15.5 below, no assignment or subletting will release Tenant from any of its obligations under this Lease unless Landlord agrees to the contrary 

  

 35 

 
in writing. Acceptance of Rent by Landlord from any person other than Tenant will not be deemed a waiver by Landlord of any provision of this
Section 15. Consent to one assignment or subletting will not be deemed a consent to any subsequent assignment or subletting. 
  

	15.6	Restrictions on Assignment and Subletting. 

 Notwithstanding anything to the contrary set forth herein, pursuant to the terms of a contractual arrangement between Landlord and BMC Software, Inc. (“BMC”), Landlord shall have not right to consent to any
assignment or subletting by Tenant to the companies listed on Exhibit H attached hereto and any additional persons or entities that BMC designates from time to time as a direct competitor of BMC in writing to Landlord (individually, an
“Excluded Company” and collectively, the “Excluded Companies”) and Tenant shall not assign or sublease the Premises (or any portion thereof) to an Excluded Company(ies) pursuant to Section 15.4
above. In no event shall the total number of Excluded Companies exceed ten (10). Landlord shall deliver copies of any such written notice received by Landlord from BMC to Tenant (together with any documentation delivered by BMC regarding the
addition of direct competitors). Tenant acknowledges that Landlord shall not be deemed to be acting unreasonably should it reject any proposed assignment or subletting because of this contractual arrangement with BMC and that Landlord shall not
be subject to any liability whatsoever for so rejecting an assignment or sublease. 
 16. PERSONAL PROPERTY. 
  

	16.1	Installation And Removal. 

 Tenant may install in
the Premises its personal property (including Tenant’s usual trade fixtures), provided that no such installation will damage or materially interfere with the mechanical, plumbing or electrical systems or the structure of the Building, and
provided further that if such installation would require any Alterations to the Premises, such installation will be subject to Section 9.1. Any such personal property installed in the Premises by Tenant (a) may be removed from the Premises
from time to time in the ordinary course of Tenant’s business or in the course of making any Alterations to the Premises permitted under Section 9.1, and (b) will be removed by Tenant at the end of the Term according to
Section 3.3. Tenant will promptly repair at its expense any damage to the Building resulting from such installation or removal. 
  

	16.2	Responsibility. 

 Tenant will be solely responsible
for all costs and expenses related to personal property used or stored in the Premises. Tenant will pay any taxes or other governmental impositions levied upon or assessed against such personal property, or upon Tenant for the ownership or use of
such personal property, on or before the due date for payment. Such personal property taxes or impositions are not included in Taxes. Tenant agrees that all personal property of whatever kind, including, without limitation, inventory and/or 

  

 36 

 
goods stored at or about the Premises, Tenant’s trade fixtures, and Tenant’s interest in tenant improvements which may be at any time located in,
on or about the Premises or the Building, whether owned by Tenant or third parties, shall be at the sole risk or at the risk of those claiming through Tenant, and that Landlord shall not be liable for any damage to or loss of such property except
for loss or damage arising from or caused by the active negligence or willful misconduct of Landlord or any of Landlord’s officers, employees, agents, or authorized representatives each acting within the scope of their authority. 
  

	16.3	Landlord’s Lien. 

 Landlord waives any and all
liens, whether statutory or at common law, which it may have upon any of the goods, wares, equipment, fixtures, furniture, improvements or personal property of Tenant located within or about the Premises. 
 17. ESTOPPEL CERTIFICATES. 
 Tenant agrees that at any
time and from time to time (but on not less than ten (10) business days prior request by Landlord), Tenant will execute, acknowledge and deliver to Landlord a certificate indicating any or all of the following: (a) the Rent Commencement
Date and Expiration Date; (b) that this Lease is unmodified and in full force and effect (or, if there have been modifications, that this Lease is in full force and effect, as modified, and stating the date and nature of each modification);
(c) the date, if any, through which Base Rent, Additional Rent and any other Rent payable have been paid; (d) that no default by Landlord, to the best of Tenant’s knowledge, or by Tenant exists which has not been cured, except as to
defaults stated in such certificate; (f) provided such events have occurred, that Tenant has accepted the Premises and that all improvements required to be made to the Premises by Landlord have been completed according to this Lease;
(g) that, except as specifically stated in such certificate, Tenant, and only Tenant (or its Affiliates so identified in the certificate), currently occupies the Premises; and (h) such other matters as may be reasonably requested by
Landlord. Any such certificate may be relied upon by the Landlord, its Affiliates, any prospective purchaser or present or prospective mortgagee, deed of trust beneficiary or ground lessor of all or a portion of the Building and/or Land. 

18. TRANSFER OF LANDLORD’S INTEREST. 
  

	18.1	Sale, Conveyance And Assignment. 

 Nothing in this
Lease will restrict Landlord’s right to sell, convey, assign or otherwise transfer the Building or Landlord’s interest under this Lease. 
  

	18.2	Effect Of Sale, Conveyance Or Assignment. 

 A sale,
conveyance or assignment of the Building will automatically release Landlord from liability under this Lease from and after the effective date of the transfer, except for 

  

 37 

 
any liability relating to or arising from the period prior to such effective date, and Tenant will look solely to Landlord’s transferee for performance
of Landlord’s obligations relating to the period after such effective date. This Lease will not be affected by any such sale, conveyance or assignment and Tenant will attorn to Landlord’s transferee. 
  

	18.3	Subordination And Nondisturbance. 

 Subject to
receipt by Tenant of a subordination, non-disturbance and attornment agreement in either: (i) the form reasonably acceptable to Landlord’s lender and Tenant or (ii) the form attached hereto as Exhibit G, this Lease shall
be subject and subordinate in all respects to any ground lease, mortgage or deed of trust to secure debt (an “Encumbrance”) encumbering the Building in the future, and to any renewal, modification, supplement, consolidation
and replacement thereto or thereof. Landlord shall use commercially reasonable efforts to obtain from any future holder of a mortgage covering the Project a subordination, non-disturbance and attornment agreement in form reasonably acceptable to
Landlord, Tenant and the holder of the mortgage. Landlord represents and warrants that as of the date hereof the Project is not currently encumbered. 
 19. RULES AND REGULATIONS. 
 Tenant agrees to faithfully observe and comply with the Rules and Regulations (“Rules
and Regulations”) set forth in Exhibit D and with all reasonable modifications and additions to such Rules and Regulations (which will be applicable to all Building tenants) from time to time adopted by Landlord and of
which Tenant is notified in writing. No such modification or addition will contradict or abrogate any right expressly granted to Tenant under this Lease or impose additional costs on Tenant. Landlord’s enforcement of the Rules and Regulations
will be uniform and nondiscriminatory, but Landlord will not be responsible to Tenant for failure of any person to comply with the Rules and Regulations. 
 20. TENANT’S DEFAULT AND LANDLORD’S REMEDIES. 
  

	20.1	Tenant’s Default. 

 The occurrence of any one
or more of the following events shall be a material default (“Default”) and breach of this Lease by Tenant: 
 (a) Tenant fails to pay Base Rent or any other payment due under this Lease after the same shall be due and payable, and such failure continues for a period of three (3) days after written notice thereof from Landlord to Tenant (but
with respect to the first installment of Additional Rent after Landlord has changed the amount of the estimated payment, Tenant shall be provided a thirty (30) day notice rather than a three (3) day notice); 
 (b) Tenant fails to perform or observe any other term, condition, covenant, or obligation required to be performed or observed by it under
this Lease for a period of 

  

 38 

 
thirty (30) days (or such shorter time provided herein) after notice thereof from Landlord; provided, however, that if the term, condition, covenant, or
obligation to be performed by Tenant is of such nature that the same cannot reasonably be cured within thirty (30) days and if Tenant commences such performance within said thirty (30) day period and thereafter diligently undertakes to
complete the same, then such failure shall not be a default hereunder if it is cured with reasonable diligence and in no event later than ninety (90) days following Landlord’s notice. 
 (c) A trustee, disbursing agent, or receiver is appointed to take possession of all or substantially all of Tenant’s assets in, on or
about the Premises or of Tenant’s interest in this Lease (and Tenant does not regain possession within sixty (60) days after such appointment); or Tenant makes an assignment for the benefit of creditors; or all or substantially all of
Tenant’s assets in, on or about the Premises or Tenant’s interest in this Lease are attached or levied upon under execution (and Tenant does not discharge the same within sixty (60) days thereafter). 
 (d) A petition in bankruptcy, insolvency, or for reorganization or arrangement is filed by or against Tenant pursuant to any federal or
state statute, and, with respect to any such petition filed against it, Tenant fails to secure a stay or discharge thereof within sixty (60) days after the filing of the same. 
 (e) Any assignment, subletting, or other transfer for which the prior written consent of the Landlord has not been obtained, except for
Permitted Transfers. 
 (f) Tenant’s admission in writing of its inability to pay its debts as they mature.

 (g) Suspension of Tenant’s right to conduct its business, caused by the order, judgment, decree, decision, or other
act of any court or government agency. 
 (h) Tenant’s failure to execute, acknowledge, and deliver to Landlord, within
ten (10) business days following written notice from Landlord that Tenant has failed to deliver any documents required to effectuate an attornment, a subordination, or to make this Lease or any option granted herein prior to the lien of any
mortgage, deed of trust, or ground lease, or any estoppel certificate, as the case may be within the time period specified in this Lease therefore. 
 (i) Tenant’s vacating of the Premises coupled with a Default by Tenant under Section 20.1(a) after the expiration of the applicable cure periods set forth therein (but vacating alone shall not be a Default).

 If the Lease is assigned, and if the assignor provides a mailing address to Landlord for purposes of notices hereunder, then Landlord shall
mail to such assignor any notice to be given to Tenant under this Section 20.1; however, the fact that any such prior Tenant does not actually receive any such notice shall not restrict Landlord’s right to exercise its remedies hereunder.
Such notice to an assignor shall not be required if such assignor is 

  

 39 

 
not liable for the default set forth in the notice. No time to cure shall be added as a result of any such mailing. Any notice required by the terms of this
Lease in connection with any such default shall be in lieu of, and not in addition to, any notice required under Sections 1161, et seq., of the California Code of Civil Procedure. 
  

	20.2	Landlord’s Remedies. 

 Upon the occurrence of
any event of Default, Landlord shall have the following rights and remedies, in addition to those allowed by law or in equity, any one or more of which may be exercised or not exercised without precluding the Landlord from exercising any other
remedy provided in this Lease or otherwise allowed by law or in equity: 
 (a) Landlord may terminate this Lease and
Tenant’s right to possession of the Premises. If Tenant has abandoned and vacated the Premises, the mere entry onto the Premises by Landlord in order to perform acts of maintenance, cure defaults, preserve the Premises, or attempt to relet the
Premises, or the appointment of a receiver in order to protect the Landlord’s interest under this Lease, shall not be deemed a termination of Tenant’s right to possession or a termination of this Lease unless Landlord has notified Tenant
in writing that this Lease is terminated. If Landlord terminates this Lease and Tenant’s right to possession of the Premises pursuant to this Subsection 20.2(a), then Landlord may recover from Tenant any and all damages set forth in California
Civil Code Section 1951.2, or any successor statute, and including without limitation the following: 
 (i) the worth at
the time of the award of unpaid rent, including, without limitation, Tenant’s Share of Additional Expenses, which had been earned at the time of termination; plus 
 (ii) the worth at the time of the award of the amount by which the unpaid rent which would have been earned after termination until the
time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus 
 (iii) the
worth at the time of the award of the amount by which the unpaid rent for the balance of the Term after the time of the award exceeds the amount of such rental loss that Tenant proves could be reasonably avoided; plus 
 (iv) the costs of repairs, cleanup, refurbishing, removal, and storage or disposal of Tenant’s personal property, equipment,
fixtures, and anything else that Tenant is required under this Lease to remove but does not remove (including those alterations which Tenant is required to remove pursuant to an election by Landlord, and which Landlord actually removes, whether or
not notice to remove shall be delivered to Tenant) to the extent necessary to compensate Landlord for the detriment proximately caused by Tenant’s Default; plus 
 (v) any costs for alterations, additions, and renovations incurred by Landlord in regaining possession of and reletting (or attempting to
relet) the Premises to the extent necessary to compensate Landlord for the detriment proximately caused by Tenant’s Default; plus 
  

 40 

 (vi) any other amount necessary to compensate Landlord for the detriment proximately
caused by Tenant’s Default. 
 However the foregoing damages expressly exclude any lost profits and expressly exclude any consequential
damages arising from a Default by Tenant. 
 All computations of the “worth at the time of the award” of amounts recoverable by
Landlord under Subsection (a)(i) and (ii) hereof shall be computed by allowing interest at the lesser of (A) ten percent (10%) or (B) the maximum legal rate allowed by law. The “worth at the time of the award”
recoverable by Landlord under Subsection (a)(iii) shall be computed by discounting the amount recoverable by Landlord at the discount rate of the Federal Reserve Bank of San Francisco at the time of the award plus one percent (1%). 
 (b) Upon termination of this Lease, whether by lapse of time or otherwise, Tenant shall immediately vacate the Premises and deliver
possession to Landlord. If Tenant is in Default under Section 20.1(j) and Landlord or any of its agents has reason to believe that Tenant does not intend to reoccupy the Premises, and current or past rent has been due or unpaid for at least
fourteen (14) consecutive days, then Landlord shall have the right to send Tenant a notice of belief of abandonment pursuant to Section 1951.3 of the California Civil Code. The Premises will be deemed abandoned, and the Tenant’s right
to possession of the Premises will terminate on the date set forth in such notice, unless Landlord receives (at its address for notices pursuant to this Lease) before such date a notice from Tenant stating (i) Tenant’s intent not to
abandon the Premises, and (ii) an address at which Tenant may be served in any action for unlawful detainer of the Premises and/or damages or other relief available at law or in equity. If the Premises are deemed abandoned pursuant to the
foregoing (either through the aforementioned procedure or due to any statement by Tenant to that effect), or if Landlord or any of its agents acts pursuant to a court order, then Landlord or any of its agents shall have the right, without
terminating this Lease, to re-enter the Premises and remove all persons therefrom and any or all of Tenant’s fixtures, equipment, furniture, and other personal property (herein collectively referred to as “Property”)
from the Premises, without being deemed in any manner liable for trespass, eviction, or forcible entry or detainer, or conversion of Property, and without relinquishing any right given to Landlord under this Lease or by operation of law. If Landlord
re-enters the Premises in such situation, all Property removed from the Premises by Landlord or any of its agents and not claimed by the owner may be handled, removed, or stored, in a commercial warehouse or otherwise by Landlord at Tenant’s
risk and expense, and Landlord shall in no event be responsible for the value, preservation, or safekeeping thereof. Before the retaking of any such Property from storage, Tenant shall pay to Landlord, upon demand, all expenses incurred in such
removal and all storage charges against such Property. Any such Property of Tenant not so retaken from storage by Tenant within thirty (30) days after such Property is removed from the Premises shall be deemed abandoned and may be either
disposed of by Landlord pursuant to Section 1988 of the California Civil Code or retained by Landlord as its own property. 
  

 41 

 (c) Notwithstanding Landlord’s right to terminate this Lease pursuant to
Section 20.2(a), Landlord may, at its option, even though Tenant has breached this Lease and abandoned the Premises, continue this Lease in full force and effect and not terminate Tenant’s right to possession, and enforce all of
Landlord’s rights and remedies under this Lease. In such event, Landlord shall have the remedy described in California Civil Code Section 1951.4 (Landlord may continue this Lease in effect after Tenant’s breach and abandonment and
recover rent as it becomes due, if Tenant has the right to sublet or assign, subject only to reasonable limitations-which Tenant agrees are set forth in this Lease). Further, in such event, Landlord shall be entitled to recover from Tenant all costs
of maintenance and preservation of the Premises, and all costs, including attorneys’ fees and receivers’ fees, incurred in connection with appointment of and performance by a receiver to protect the Premises and Landlord’s interest
under this Lease. No reentry or taking possession of the Premises by Landlord pursuant to this Section 20.2(c) shall be construed as an election to terminate this Lease unless a written notice (signed by a duly authorized representative of
Landlord) of intention to terminate this Lease is given to Tenant. Landlord may at any time after Default by Tenant elect to terminate this Lease pursuant to Section 20.2(a), notwithstanding Landlord’s prior continuance of this Lease in
effect for any period of time, and upon and after Tenant’s Default under this Lease, Landlord may, but need not, relet the Premises or any part thereof for the account of Tenant to any Person for such rent, for such time, and upon such terms as
Landlord, in its sole discretion, shall determine. Subject to the provisions of this Lease regarding assignment and subletting in Section 15, Landlord shall not be required to accept any substitute tenant offered by Tenant or to observe any
instructions given by Tenant regarding such reletting. Landlord may remove (and repair any damage caused by such removal) and store (or dispose of) any of Tenant’s personal property, equipment, fixtures, and anything else Tenant is required
(under this Lease at the election of Landlord or otherwise) to remove but does not remove, and Landlord may also make repairs, renovations, alterations, and/or additions to the Premises to the extent deemed by Landlord necessary or desirable in
connection with any attempt to relet the Premises. Tenant shall upon demand pay the cost of such repairs, alterations, additions, removal, storage, and renovations, together with any reasonable legal expenses, brokers commissions, or finders fees
and any other reasonable expenses incurred by Landlord in connection with its entry upon the Premises and attempt to relet the Premises. If Landlord is able to relet the Premises for Tenant’s account during the remaining portion of the Term and
the consideration collected by Landlord from any reletting is not sufficient to pay monthly the full amount of rent and additional rent payable by Tenant under this Lease, together with any reasonable legal expenses, brokers commissions, or finders
fees, any reasonable cost for repairs, alterations, additions, removal, storage, and renovations, and any other reasonable cost and expense incurred by Landlord in reentering the Premises and reletting the Premises, then Tenant shall pay to Landlord
the amount of each monthly deficiency upon demand. Any rentals received by Landlord from any such reletting shall be applied as follows: 
 (i) First, to the payment of any indebtedness other than rent due hereunder from Tenant to Landlord; 
  

 42 

 (ii) Second, to the payment of any reasonable costs of reentry and reletting the
Premises; 
 (iii) Third, to the payment of reasonable costs of any such alterations, repairs, additions, removal, storage,
and renovations to the Premises; 
 (iv) Fourth, to the payment of rent due and unpaid under this Lease; and 
 (v) The residue, if any, shall be held by Landlord and applied as payment of future rent as the same may become due and payable under this
Lease. 
 (d) No act or omission by Landlord or its agents during the Term shall be an acceptance of a surrender of the
Premises, and no agreement to accept a surrender of the Premises shall be valid, unless made in writing and signed by a duly authorized representative of Landlord. Neither any remedy set forth in this Lease nor pursuit of any particular remedy shall
preclude Landlord from any other remedy set forth in this Lease or otherwise available at law or in equity. Landlord shall be entitled to a restraining order or injunction to prevent Tenant from breaching or defaulting under any of its obligations
under this Lease other than the payment of rent or other sums due hereunder. 
 (e) Neither the termination of this Lease nor
the exercise of any remedy under this Lease or otherwise available at law or in equity shall affect the right of Landlord to any right of indemnification set forth in this Lease or otherwise available at law or in equity by reason of Tenant’s
occupancy of the Premises, and all rights to indemnification or other obligations of Tenant shall survive termination of this Lease and termination of Tenant’s right to possession under this Lease. 
 21. LANDLORD DEFAULT AND TENANT’S REMEDIES. 
  

	21.1	Landlord Default. 

 It shall be a default and breach
of this Lease by Landlord if Landlord shall fail to perform or observe any term, condition, covenant, or obligation required to be performed or observed by it under this Lease (other than Landlord’s obligations under Sections 7.4 and 12.2,
which shall be governed by those Sections) for a period of thirty (30) days after written notice thereof from Tenant; provided, however, that if the term, condition, covenant, or obligation to be performed by Landlord is of such nature that the
same cannot reasonably be performed within such thirty (30) day period, such default shall be deemed to have been cured if Landlord commences such performance within said thirty (30) day period and thereafter diligently undertakes to
complete the same. 
  

 43 

	21.2	Tenant’s Remedies. 

 If Landlord breaches or
fails to comply with any provisions of this Lease applicable to Landlord, and such breach or noncompliance is not cured within the period of time described in Section 21.1, then Tenant may exercise any right or remedy available to Tenant under
this Lease, at law or in equity, except to the extent expressly waived or limited by the terms of this Lease. 
 22. SECURITY DEPOSIT. 
 Landlord and Tenant acknowledge that there is no security deposit under this Lease. 
 23. BROKERS. 
 Landlord and Tenant represent and warrant that no broker or agent negotiated or was
instrumental in negotiating or consummating this Lease except the Brokers. Neither party knows of any other real estate broker or agent who is or might be entitled to a commission or compensation in connection with this Lease. Landlord will pay all
fees, commissions or other compensation payable to the Brokers pursuant to separate agreement between Landlord and the Brokers. Tenant and Landlord will indemnify, defend and hold each other harmless from all damages paid or incurred by the other
resulting from any claims asserted against either party by brokers or agents claiming through the other party, other than the Brokers. Landlord’s obligation under this Section 23 will survive the expiration or early termination of the
Term. 
 24. LIMITATIONS ON LANDLORD’S LIABILITY. 
 Notwithstanding any other provision herein, any liability for damages, breach or nonperformance by Landlord, or arising out of the subject matter of, or the relationship created by, this Lease, will be collectible
only out of Landlord’s interest in the Building and any insurance or condemnation proceeds received with respect thereto (or if Landlord has transferred the Building the proceeds of such transfer if the event giving rise to the claim occurred
prior to the transfer of the Building) and no liability will at any time be asserted against any other assets of Landlord, its parent and affiliated corporations, its and their partners, venturers, directors, officers, agents, servants and
employees, or any of its or their successors or assigns; all such liability, if any, being expressly waived and released by Tenant. 
 25. NOTICES. 

 Except in connection with an unlawful detainer action, in which case notice shall be given in the manner required under the applicable
unlawful detainer statute, all notices required or permitted under this Lease must be in writing and will only be deemed properly given and received (a) when actually given and received, if delivered in person to a party; or (b) one
business day after deposit with a private courier or overnight delivery service, if such courier or service obtains a written acknowledgment of receipt, or (c) four days after deposit in the US Mail certified return receipt requested. Except in

  

 44 

 
connection with an unlawful detainer action, in which case such notice shall be given in the manner required under the applicable unlawful detainer statute,
all notices must be transmitted by one of the methods described above to the party to receive the notice at, in the case of notices to Landlord, Landlord’s Address, and in the case of notices to Tenant, the Tenant’s Notice Address, or, in
either case, at such other address(es) as either party may notify the other of according to this Section 25; provided that at no time may Tenant designate more than four (4) addresses for notice. Time shall be of the essence for the giving
of all notices required or permitted under the provisions of this Lease. 
 26. MISCELLANEOUS. 
  

	26.1	Binding Effect. 

 Each of the provisions of this
Lease will extend to bind or inure to the benefit of, as the case may be, Landlord and Tenant, and their respective heirs, successors and assigns, provided this clause will not permit any transfer by Tenant contrary to the provisions of
Section 15. 
  

	26.2	Complete Agreement; Modification. 

 All of the
representations and obligations of the parties are contained in this Lease and no modification, waiver or amendment of this Lease or of any of its conditions or provisions will be binding upon a party unless in writing signed by such party.

  

	26.3	Delivery for Examination. 

 Submission of the form
of the Lease for examination will not bind Landlord in any manner, and no obligations will arise under this Lease until it is signed by both Landlord and Tenant and delivery is made to each. 
  

	26.4	No Air Rights. 

 This Lease does not grant any
easements or rights for light, air or view. Any diminution or blockage of light, air or view by any structure or condition now or later erected will not affect this Lease or impose any liability on Landlord. 
  

	26.5	Enforcement Expenses. 

 Each party agrees to pay,
upon demand, all of the other party’s costs, charges and expenses, including the fees and out-of-pocket expenses of counsel, agents, and others retained, incurred in successfully enforcing the other party’s obligations under this Lease.

  

	26.6	Waiver of Consequential Damages. 

 Neither Landlord
nor Tenant shall be liable to the other (or any person or entity claiming by, through or under the other) for, and each hereby releases and waives any claims with respect to, any consequential damages arising under or in connection with this Lease.

  

 45 

	26.7	Building Name. 

 Landlord shall have the right to
name (and rename) the Building as Landlord desires, from time to time. 
  

	26.8	Project Modifications. 

 Landlord reserves the right
to make reasonable alterations to all areas of the Project that are not within the Premises or within any other areas as to which Tenant has exclusive use rights, so long as the same do not adversely impact Tenant’s ability to utilize the
Premises or the Project. 
  

	26.9	No Waiver. 

 No waiver of any provision of this
Lease will be implied by any failure of either party to enforce any remedy upon the violation of such provision, even if such violation is continued or repeated subsequently. No express waiver will affect any provision other than the one specified
in such waiver, and that only for the time and in the manner specifically stated. 
  

	26.10	Recording; Confidentiality. 

 Intentionally Deleted.

  

	26.11	Captions. 

 The captions of sections are for
convenience only and will not be deemed to limit, construe, affect or alter the meaning of such sections. 
  

	26.12	Invoices. 

 All bills or invoices to be given by
Landlord to Tenant will be sent to Tenant’s Invoice Address. Tenant may change Tenant’s Invoice Address by notice to Landlord given according to Section 25 provided only one address at any time shall be given as Tenant’s Invoice
Address. 
  

	26.13	Severability. 

 If any provision of this Lease is
declared void or unenforceable by a final judicial or administrative order, this Lease will continue in full force and effect, except that the void or unenforceable provision will be deemed deleted and replaced with a provision as similar in terms
to such void or unenforceable provision as may be possible and be valid and enforceable. 
  

 46 

	26.14	Jury Trial. 

 EACH PARTY TO THIS LEASE HEREBY
EXPRESSLY WAIVES ANY RIGHT TO TRIAL BY JURY OF ANY CLAIM, DEMAND, ACTION OR CAUSE OF ACTION ARISING HEREUNDER WHETHER SUCH CLAIM, DEMAND, ACTION OR CAUSE OF ACTION IS NOW EXISTING OR HEREAFTER ARISING, AND WHETHER SOUNDING IN CONTRACT OR TORT OR
OTHERWISE; AND EACH PARTY HEREBY AGREES AND CONSENTS THAT ANY SUCH CLAIM, DEMAND, ACTION OR CAUSE OF ACTION SHALL BE DECIDED BY COURT TRIAL WITHOUT A JURY, AND THAT ANY PARTY TO THIS LEASE MAY FILE AN ORIGINAL COUNTERPART OR A COPY OF THIS SECTION
WITH ANY COURT AS WRITTEN EVIDENCE OF THE CONSENT OF THE PARTIES HERETO TO THE WAIVER OF ANY RIGHT THEY MIGHT OTHERWISE HAVE TO TRIAL BY JURY. NOTWITHSTANDING THE FOREGOING TO THE CONTRARY, IN THE EVENT THAT THE JURY TRIAL WAIVER CONTAINED HEREIN
SHALL BE HELD OR DEEMED TO BE UNENFORCEABLE, EACH PARTY HERETO HEREBY EXPRESSLY AGREES TO SUBMIT TO JUDICIAL REFERENCE PURSUANT TO CALIFORNIA CODE OF CIVIL PROCEDURE SECTIONS 638 THROUGH 645.1 ANY CLAIM, DEMAND, ACTION OR CAUSE OF ACTION ARISING
HEREUNDER FOR WHICH A JURY TRIAL WOULD OTHERWISE BE APPLICABLE OR AVAILABLE. PURSUANT TO SUCH JUDICIAL REFERENCE, THE PARTIES AGREE TO THE APPOINTMENT OF A SINGLE REFEREE AND SHALL USE THEIR BEST EFFORTS TO AGREE ON THE SELECTION OF A REFEREE. IF
THE PARTIES ARE UNABLE TO AGREE ON A SINGLE A REFEREE, A REFEREE SHALL BE APPOINTED BY THE COURT UNDER CALIFORNIA CODE OF CIVIL PROCEDURE SECTIONS 638 AND 640 TO HEAR ANY DISPUTES HEREUNDER IN LIEU OF ANY SUCH JURY TRIAL. THE PARTIES ACKNOWLEDGE AND
AGREE THAT THE APPOINTED REFEREE SHALL HAVE THE POWER TO DECIDE ALL ISSUES IN THE APPLICABLE ACTION OR PROCEEDING, WHETHER OF FACT OR LAW, AND SHALL REPORT A STATEMENT OF DECISION THEREON; PROVIDED, HOWEVER, THAT ANY MATTERS WHICH WOULD NOT
OTHERWISE BE THE SUBJECT OF A JURY TRIAL WILL BE UNAFFECTED BY THIS WAIVER AND THE AGREEMENTS CONTAINED HEREIN. THE PARTIES HERETO HEREBY AGREE THAT THE PROVISIONS CONTAINED HEREIN HAVE BEEN FAIRLY NEGOTIATED ON AN ARMS-LENGTH BASIS, WITH BOTH SIDES
AGREEING TO THE SAME KNOWINGLY AND BEING AFFORDED THE OPPORTUNITY TO HAVE THEIR RESPECTIVE LEGAL COUNSEL CONSENT TO THE MATTERS CONTAINED HEREIN. ANY PARTY TO THIS LEASE MAY FILE AN ORIGINAL COUNTERPART OR A COPY OF THIS SECTION WITH ANY COURT AS
WRITTEN EVIDENCE OF THE CONSENT OF THE PARTIES HERETO TO THE WAIVER OF THEIR RIGHT TO TRIAL BY JURY AND THE AGREEMENTS CONTAINED HEREIN REGARDING THE APPLICATION OF JUDICIAL REFERENCE IN THE EVENT OF THE INVALIDITY OF SUCH JURY TRIAL WAIVER.

  

 47 

	26.15	Authority to Bind. 

 The individuals signing this
Lease on behalf of Landlord and Tenant represent and warrant that they are empowered and duly authorized to bind Landlord or Tenant, as the case may be, to this Lease according to its terms. 
  

	26.16	Only Landlord/Tenant Relationship. 

 Landlord and
Tenant agree that neither any provision of this Lease nor any act of the parties will be deemed to create any relationship between Landlord and Tenant other than the relationship of landlord and tenant. 
  

	26.17	Covenants Independent. 

 The parties intend that
this Lease be construed as if the covenants between Landlord and Tenant are independent and not dependent and that the Rent will be payable without offset, reduction or abatement for any cause except as otherwise specifically provided in this
Lease. 
  

	26.18	Governing Law. 

 This Lease will be governed by and
construed according to the laws of the State of California. 
  

	26.19	Consent and Approval Standard. 

 Unless otherwise
expressly provided in this Lease, in any instance in which the consent or approval of Landlord or Tenant is required to be obtained by the other party hereunder, such consent or approval shall not be unreasonably withheld, conditioned or delayed.

 27. OPTIONS TO EXTEND THE TERM. 
  

	27.1	Grant of Extension Options. 

 Provided that Tenant
is not in Default at the time of its exercise of this option or as of the commencement of the Extension Term, Tenant shall have the option to extend the Term of the Lease (“Extension Option”) for (1) one additional term
of five (5) years (“Extension Term”). The Extension Option shall entitle Tenant to extend the Term of this Lease as to all of the Premises. 
  

	27.2	Exercise of Extension Option. 

 Tenant shall notify
Landlord in writing (the “Tenant’s Extension Notice”) of its intention (subject to the terms and provisions hereof) to exercise the option granted herein no earlier than the date that is two hundred seventy
(270) days and no later than the date that is one hundred fifty (150) days prior to the termination of the then existing Term of this Lease or this Extension Option shall automatically be canceled and of no further force and effect, time
expressly being of the essence. 
  

 48 

	27.3	Determination of Extension Annual Base Rental Rate. 

 Within thirty (30) days following the receipt of Tenant’s Extension Notice, Landlord shall notify Tenant in writing of Landlord’s determination of the “Extension Annual Base Rental Rate” which shall be
one hundred percent (100%) of the Market Rate as of the time of Tenant’s Extension Notice, determined as provided in Section 29.1 below. If the parties are unable to agree upon a Market Rate for the Extension Term within sixty
(60) days following the date of Landlord’s notice, Tenant shall elect (by written notice delivered to Landlord) to (i) decline to exercise the Extension Option or (ii) elect to exercise the Extension Option and submit the
determination of Market Rate to arbitration as provided in Section 29.2, the determination of which shall be binding upon both Landlord and Tenant. The failure by Tenant to timely notify Landlord of its election shall be deemed to constitute
Tenant’s election pursuant to clause (i) in the immediately preceding sentence, whereupon all rights and privileges granted to Tenant to renew or extend this Lease shall automatically terminate. If for any reason the Market Rate shall not
have been determined prior to the commencement of the Extension Term, then, until the Market Rate and, accordingly, the Extension Annual Base Rental Rate, shall have been finally determined, the Annual Base Rental Rate per Rentable Square Foot in
the Premises shall be one hundred percent (100%) of the rate specified in Landlord’s notice as the Market Rate. Upon final determination of the Market Rate, an appropriate adjustment to the Annual Base Rental Rate per rentable square foot
in the Premises shall be made reflecting such final determination, and Landlord and Tenant, as the case may be, shall promptly refund or pay to the other any overpayment or deficiency, as the case may be, in the payment of Base Rent from the
commencement of the Extension Term to the date of such final determination. 
 28. RIGHT OF FIRST OFFER. 
  

	28.1	Grant of Right of First Offer. 

 (a)
Throughout the Term of this Lease, Tenant shall have one time right of first offer to lease (the “ROFO”) the currently vacant approximately 11,059 Rentable Square Feet located on the third floor of the Building which is
identified on Exhibit A-3 (the “ROFO Space”). Landlord shall notify Tenant of the availability of the ROFO Space (“ROFO Offer Notice”) which such ROFO Offer Notice shall set forth
Landlord’s determination of the Market Rate, and a complete copy of any letters of intent, proposals, leases or other writings indicating the terms and conditions of such proposed lease, if applicable. 
 (b) The Annual Base Rental Rate with respect to the ROFO Space shall be one hundred percent (100%) of the Market Rate. In determining
the Market Rate applicable to the ROFO Space, Additional Rent shall be calculated pursuant to Section 4 of this Lease as follows: the Base Year shall be the calendar year in which the term for the ROFO Space commences; and Tenant’s Share
shall be determined by the ratio of the ROFO Space to the total number of Rentable Square Feet contained in the Building. 
  

 49 

 (c) Tenant shall have a period of ten (10) days after receipt of a ROFO Offer Notice
to notify Landlord in writing of either (A) its election to lease such space at the Market Rate if Landlord and Tenant have agreed to the Market Rate during the applicable time period or (B) its election to decline to lease such space or
(C) its election to lease such space while leaving the determination of Market Rate to arbitration in accordance with Section 29.2, which shall be binding upon the parties. If Tenant fails to timely notify Landlord regarding (A),
(B) or (C) in the preceding sentence within the applicable time period, Tenant shall be deemed to have elected to decline to lease such space, and Landlord may lease the subject space to any third party on any terms. Tenant’s ROFO
shall apply to the ROFO Space regardless of whether Tenant has previously failed to exercise its ROFO or any other right with respect to all or any portion of the ROFO Space. 
 (e) If Tenant elects to lease space pursuant to this Section 28, Tenant and Landlord shall execute an amendment, reflecting the
agreed upon terms, within thirty (30) days after agreement is reached regarding such terms, if at all. 
 29. DETERMINATION OF MARKET RATE.

  

	29.1	Definition of Market Rate. 

 As used in this Lease,
“Market Rate” shall mean the then prevailing fair market effective rental rate (which rate could include the payment of a tenant improvement allowance by Landlord, to the extent it is part of fair market rental rate
structure), based on tenancies (for a term comparable to the time period in question) covering office space of comparable size and condition to the space in question in comparable buildings in comparable locations in the Pleasanton area including
Hacienda Business Park and the Building, determined on a “gross” lease basis (with “gross” meaning terms substantially similar to this Lease) as of the date Tenant exercises the applicable option taking into account
the following: (1) the location, quality and age of the building; (2) location, size and/or floor levels of the space in question, including view, elevator, lobby exposure, etc.; (3) definition of “rentable” area;
(4) extent of leasehold improvements in the space in question or to be provided, and/or any allowance for same; (5) abatements (including base rental, operating expenses and real estate taxes, and parking charges); (6) inclusion
and/or exclusion of parking charges in rental; (7) lease takeovers and assumptions; (8) programming/space planning/interior architecture and engineering allowances; (9) relocation allowances; (10) refurbishment allowances;
(11) distinction between “gross,” “modified gross” and “net” leases; (12) base year or dollar amounts for escalation purposes; (13) any other adjustments (including, for example, by way of indices) to
base rental; (14) credit standing of Tenant and any applicable tenant; (15) term or length of lease; (16) the time the particular rental rate under consideration was agreed upon and becomes or is to become effective; and (17) any
other concession or inducement and/or relevant terms or conditions that a reasonable and knowledgeable real estate professional 

  

 50 

 
would include in making such fair value rental rate determination. In each and every instance under this Lease in which the Market Rate is to be determined,
integral to such determination shall be all relevant economic factors as enumerated above, including, without limitation, lease takeovers, abatements, leasehold improvements and other allowances, etc. The valuation shall be based on the highest and
best use of the Premises permitted under this Lease and not necessarily the use being made by Tenant. 
  

	29.2	Determination by Arbitration. 

 If submitted to
arbitration, Market Rate for the space in question for the applicable term shall be determined in accordance with this Section 29.2. Within fifteen (15) days following Tenant’s election to submit the determination of Market Rate to
arbitration, Tenant and Landlord shall simultaneously exchange in writing signed by the respective parties, in person, their respective determinations of Market Rate for the space in question for the applicable term (in each respective case the
“Landlord’s Market Rate” and the “Tenant’s Market Rate”). In the event the Landlord’s Market Rate and the Tenant’s Market Rate differ by less than five percent (5%) per
rentable square foot per annum during the applicable term (amortizing any upfront concessions, e.g., leasehold improvements, rental abatements, etc., over the applicable term), then the Market Rate for the space in question for the applicable term
shall be the average of the Landlord’s Market Rate and the Tenant’s Market Rate. If the Landlord’s Market Rate and the Tenants Market Rate differ by five percent (5%) or more per rentable square foot per annum during the
applicable term, then the Market Rate shall be determined by arbitration and Landlord and Tenant shall, within thirty (30) days following the exchange of the parties respective Market Rate determinations mutually agree upon a third party
arbitrator satisfactory to both parties to render a final determination of the Market Rate. If Landlord and Tenant are unable to mutually agree upon an arbitrator within such period, the parties shall then apply to the American Arbitration
Association (“AAA”) or any successor thereto for the designation of an arbitrator to render a final determination of the Market Rate. In either event the arbitrator shall (a) be a real estate broker licensed in the State
of California, (b) have at least ten (10) years experience in the field of office leasing (including at least five (5) years experience in Northern California-preferably in Pleasanton but not required), (c) not have individually
represented either Landlord or Tenant during the preceding five (5) year period, (d) have been involved in transactions comprising at least 3,000,000 square feet in the aggregate and involved in at least 10 transactions in excess of 50,000
Rentable Square Feet, and (e) be generally experienced and competent in determining market rates for office space similar to the space in question. The arbitrator shall conduct such hearings and investigations as the arbitrator shall deem
appropriate and shall, within thirty (30) days after having been appointed, choose either Tenant’s Market Rate or Landlord’s Market Rate, and that choice by the arbitrator shall be binding upon Landlord and Tenant as the Market Rate
for the space in question for the applicable term. Each party shall pay its own counsel fees and expenses, if any, in connection with any arbitration under this Section 29.2, and the parties shall share equally all other expenses and fees of
any such arbitration. The arbitrator shall not have the power to add to, modify, or change any of the provisions of this Lease. 
  

 51 

 30. TERMINATION OPTION. 
 Tenant may terminate this Lease in its entirety effective as of the last day of the sixtieth (60
th) full calendar month following the Rent Commencement Date (“Termination Date”) by delivering to Landlord written
notice (“Termination Notice”) thereof at least six (6) months before the Termination Date. As a pre-condition to such termination, Tenant shall pay to Landlord, not later than ninety (90) days after the delivery of
the Termination Notice, a termination fee equal to One Hundred Twenty Five Thousand and No/100 Dollars ($125,000.00) and Tenant shall vacate such space in the condition required by this Lease on or before the date the Termination Date. 

31. SIGNAGE. 
  

	31.1	Interior Signage. 

 Tenant shall have the
nonexclusive right to install appropriate signage, logo (including the signage and logo of any Affiliate of Tenant that is occupying any portion of the Premises), suite numbers, etc. on the walls of third floor elevator lobbies and within the north
lobby of the Building. Tenant shall have the exclusive right to install appropriate signage, logo (including the signage and logo of any Affiliate of Tenant that is occupying any portion of the Premises), suite numbers, etc. on the entrance door to
the Premises. The cost of any such signage shall be Tenant’s sole expense, except as set forth in Section 31.5 below. 
  

	31.2	Façade and Monument Signage. 

 (a) Tenant shall have the nonexclusive right to the parapet signage on the northwest side of the Building at the top of the Building. If permitted by HBPOA covenants, conditions and restrictions or association documents, Tenant shall also
have the non-exclusive right to have its name and logo displayed on one band of the monument sign located near Inglewood Drive on the north side of the Building. If under Section 15 an assignee or sublessee is entitled to any of Tenant’s
signage rights, the right of such assignee and sublessee to utilize such signage shall be subject to the requirements of Section 31.3. 
  

	31.3	Signage Approval. 

 (a) Any signage
of Tenant shall be subject to (i) Landlord’s approval, (ii) existing sign guidelines under regulations of applicable governmental authorities, (iii) HBPOA approval, and (iv) City of Pleasanton permitting requirements.

  

	31.4	Maintenance and Repair. 

 Other than as set forth in
Section 31.5 below, Tenant shall pay the cost of installing and removing (and repairs required as a result thereof) all signage and any repairs and maintenance required in connection therewith. Tenant, at Tenant’s cost, shall clean and
maintain such signage as is customary. 
  

 52 

	31.5	Directory Listing and Standard Suite Signage. 

 Landlord, at Landlord’s cost, shall list Tenant’s name on the Building Standard directory listings on the multi-tenant building directory located in the north lobby of the Building and shall install a Building Standard sign on or
adjacent to the entrance door of the Premises with Tenant’s name. 
 32. ROOFTOP COMMUNICATIONS EQUIPMENT. 
  

	32.1	Right to Install Antennas. 

 In addition to the
other rights granted by this Lease, Tenant shall have the right but not the obligation, during the Term to install, maintain and operate not more than two (2) satellite dishes and/or whip antennae or similar rooftop antenna (the
“Antennas”) on the Building’s roof (the “Roof”) in a location reasonably designated by Landlord (the “Antenna Site”). Tenant may also use the Building’s risers,
conduits and towers for purposes of installing cabling from the Antennas to the Premises in the interior of the Building. Tenant shall pay no additional charge for such rights during the Term. 
  

	32.2	Right of Use/Ownership of Antennas. 

 Landlord shall
have the right to use the remainder of the Roof and for permitting other tenants in the Building to lease space on the Roof and in any event only if (a) Tenant continues to have reasonable access to the Antenna Site and the Antennas, and
(b) any other equipment installed on the Roof pursuant to leases or other agreements entered into after the date of this Lease will not interfere with the Antennas’ ability to receive. 
  

	32.3	Installation, Maintenance, Operation and Removal of Antennas. 

 Tenant shall install and maintain the Antennas and related cabling at its sole expense. Prior to installation, Landlord shall have the right to approve the type, size, height, weight, location, and method of Antenna
attachment of any Antennas, which approval shall not be unreasonably withheld, conditioned, or delayed. Without limiting the foregoing, Landlord shall have the right to require Tenant to install decorative screening and fencing in order to shield
the Antennas from view, so long as such screening and fencing does not adversely affect the performance of the Antennas. Prior to installation, Tenant shall submit to Landlord and obtain Landlord’s approval of plans and specifications for the
installation and such other information reasonably required by Landlord (which approval shall not be unreasonably withheld, conditioned or delayed). Tenant shall have access to the Antenna Site at all times, subject to any reasonable restrictions of
Landlord. The installation of the Antennas shall be completed in a workmanlike manner and in accordance with all applicable Laws. Tenant shall install the Antennas using non-penetrating roof mounts. Tenant shall comply with all floor load
limitations. At the termination of this Lease (whether upon the Expiration Date or 

  

 53 

 
otherwise) Tenant shall, at Tenant’s sole cost and expense, remove the Antennas and restore the Antenna Site to the condition it was prior to
installation of the Antennas, reasonable wear and tear and damage due to fire or other casualty excepted. 
  

	32.4	Compliance with Laws. 

 Tenant shall comply in all
material respects with all applicable Laws governing the installation and operation of the Antennas. Tenant shall be responsible for obtaining, if required, any building permits and any licenses or permits required by Federal Communication
Commission, the Federal Aviation Administration or any other governmental agency having jurisdiction over the Building. If required by any such governmental agencies, Tenant shall paint the dish portion of the Antennas. Landlord agrees to reasonably
assist and cooperate, at no cost to Landlord, with Tenant to obtain any appropriate licenses or permits. 
  

	32.5	Termination. 

 All rights granted to Tenant pursuant
to this Section 32 shall automatically terminate upon the expiration of this Lease or earlier termination thereof. 
  

	32.6	Prior Rights. 

 Tenant’s rights hereunder are
subject to all rights of tenants at the Project as of the Date of this Lease to install and maintain similar equipment at the Project. The Landlord, at its sole option, may require the Tenant at any time prior to the expiration of this Lease, to
terminate the operation of the Antennas if it is (i) causing physical damage to the structural integrity of the Building, (ii) causing a safety hazard, (iii) interfering with any other service provided by the Building or Project, or
(iv) interfering with any other tenant’s business (existing on the date of this Lease). If the Tenant promptly corrects the item(s) in i-iv caused by the Antennas to the Landlord’s reasonable satisfaction, the Tenant may restore its
operation. If, the Tenant is unable or unwilling to correct that item(s) in i-iv caused by the Antennas to the Landlord’s reasonable satisfaction, Landlord, in its sole discretion, may require Tenant to remove the Antennas at Tenant’s own
cost and expense. 
 33. ARBITRATION. 
 Other than the determination of the Market Rate pursuant to Section 29.2 (which shall be resolved in accordance with such Section), the submittal of all matters to arbitration in accordance with the provisions of this Section is the
sole and exclusive method, means and procedure to resolve any and all claims, disputes or disagreements arising under this Lease, including, but not limited to Landlord’s failure to approve an assignment, sublease or other transfer of
Tenant’s interest under this Lease, or any other defaults by Landlord or Tenant except for (i) unlawful detainer proceedings brought by Landlord to gain possession of the Premises or terminate Tenant’s right of possession to the
Premises (including any defenses, but not counterclaims, of Tenant thereto), and (ii) claims for 

  

 54 

 
specific performance of any obligations under this Lease, which disputes shall be resolved by suit filed in the Superior Court of Alameda County, California,
the decision of which court shall be subject to appeal pursuant to applicable law. The parties hereby irrevocably waive any and all rights to the contrary and shall at all times conduct themselves in strict, full, complete and timely accordance with
the provisions of this Section and all attempts to circumvent the provisions of this Section shall be absolutely null and void and of no force or effect whatsoever. 
 Any dispute to be arbitrated pursuant to the provisions of this Section shall be determined by binding arbitration before a retired judge of the Superior Court of the State of California (the
“Arbitrator”) under the auspices of Judicial Arbitration & Mediation Services, Inc. (“JAMS”). Such arbitration shall be deemed initiated by either party sending written notice (the
“Arbitration Notice”) of a demand to arbitrate to the other party and to JAMS. The Arbitration Notice shall contain a description of the subject matter of the arbitration, the dispute with respect thereto, the amount
involved, if any, and the remedy or determination sought. The parties may agree on a retired judge from the JAMS panel. If they are unable to agree within fourteen (14) days after initiating the Arbitration, either party may direct JAMS to
immediately provide a list of three available judges and each party may strike one (the strike list must be returned to JAMS within fourteen (14) days after receipt thereof, failing which either party may direct JAMS to immediately select the
Arbitrator from the remaining judge (or if there are two, from the remaining two judges)). The remaining judge (or if there are two, the one selected by JAMS) will serve as the Arbitrator. In the event that JAMS shall no longer exist or if JAMS
fails or refuses to accept submission of such dispute, then the dispute shall be resolved by binding arbitration before AAA under the AAA’s commercial arbitration rules then in effect. 
 The Arbitrator shall schedule a pre-hearing conference to resolve procedural matters, arrange for the exchange of information, obtain stipulations, narrow
the issues and provide a schedule for the Arbitration. The parties will submit proposed discovery schedules to the Arbitrator at the pre-hearing conference. The scope and duration of discovery will be within the sole discretion of the Arbitrator.
The Arbitrator shall have the discretion to order a pre-hearing exchange of information by the parties, including, without limitation, production of requested documents, exchange of summaries of testimony of proposed witnesses, and examination by
deposition of parties and third-party witnesses. This discretion shall be exercised in favor of discovery reasonable under the circumstances. 
 The arbitration shall be conducted in Alameda County, California. Any party may be represented by counsel or other authorized representative. In rendering a decision(s), the Arbitrator shall determine the rights and obligations of the
parties according to the substantive and procedural laws of the State of California and the provisions of this Lease. The Arbitrator’s decision shall be based on the evidence introduced at the hearing, including all logical and reasonable
inferences therefrom. The Arbitrator may make any determination, and/or grant any remedy or relief (an “Arbitration Award”) that is just and equitable and not inconsistent with the provisions of this Lease, including without

  

 55 

 
limitation, Sections 20, 21 and 26.6. The decision must be based on, and accompanied by, a written statement of decision explaining the factual and legal
basis for the decision as to each of the principal controverted issues. The decision shall be conclusive and binding, and it may thereafter be confirmed as a judgment by the Superior Court of the State of California, subject only to challenge on the
grounds set forth in the California Code of Civil Procedure Section 1286.2. The validity and enforceability of the Arbitrator’s decision is to be determined exclusively by the California courts pursuant to the provisions of this Lease. The
Arbitrator may award costs, including without limitation attorneys’ fees, and expert and witness costs, to the prevailing party, if any, as determined by the Arbitrator in his discretion. The Arbitrator’s fees and costs shall be paid by
the non-prevailing party as determined by the Arbitrator in his discretion. A party shall be determined by the Arbitrator to be the prevailing party if its proposal for the resolution of dispute (including attorney fee liability to the date of such
proposal) is the closer to that adopted by the Arbitrator. 
 During the pendency of any arbitration or other proceedings, Tenant shall
continue to pay all Rent and Landlord and Tenant shall perform their respective obligations under this Lease. 
 Prior to the constitution of
the arbitration tribunal, and thereafter as necessary in an emergency or to enforce the arbitrator’s rulings or in the absence of the jurisdiction of the arbitrators to rule on interim measures, any party may apply to a court of applicable
jurisdiction for interim measures or emergency relief, and the parties agree that seeking and obtaining such measures shall not waive the right to arbitration. 
 [SIGNATURE PAGE ATTACHED] 
  

 56 

 Having read and intending to be bound by the terms and provisions of this Lease, Landlord and Tenant have signed it as of
the Date. 
  

					
	TENANT:	 	ADEPT TECHNOLOGY, INC.,
		 	a Delaware corporation
			
		 	By:	 	  

		 	Name:	 	  

		 	Its:	 	  

			
		 	By:	 	  

		 	Name:	 	  

		 	Its:	 	  

		
	LANDLORD:	 	PARK LAKE APARTMENTS, L.P.,
		 	a California limited partnership
			
		 	By:	 	  

		 	Name:	 	Carlo Zocchi
		 	Its:	 	General Partner

 The authorized officers of Tenant must sign on behalf of the corporation and indicate the capacity in which they
are signing. The Lease must be executed by the president or a vice-president and the secretary or an assistant secretary, unless the bylaws or a resolution of the board of directors shall otherwise provide, in which event, the bylaws or a certified
copy of the resolution, as the case may be, must be attached to this Lease. 

 SCHEDULE 1 
 LEGAL DESCRIPTION 
 All of that certain real property located in the City of Pleasanton, County of Alameda, State of
California and described as follows: 
 LOST 14B OF PARCEL MAP NO. 4517, FILED FEBRUARY 26, 1985, IN BOOK 152 OF MAPS, PAGES 24 AND 25, ALAMEDA COUNTY
RECORDS. 

 EXHIBIT A -1 
 INITIAL PREMISES 
 FIRST FLOOR 
 [Attached] 

 EXHIBIT A -2 
 INITIAL PREMISES 
 THIRD FLOOR 
 [Attached] 

 EXHIBIT A -3 
 ROFO SPACE 
 [Attached] 

 EXHIBIT B-1 
 WORK LETTER 
 This work letter (“Work Letter”) shall set forth the terms and
conditions relating to the construction of the tenant improvements in the First Floor Premises (“First Floor Tenant Improvements”) by Landlord in the First Floor Premises, at no cost to Tenant, except as otherwise set forth
in Sections 3.2. 3.5 and 4.1 below. 
 SECTION 1: CONSTRUCTION OF WORK BY LANDLORD 
 1.1 Landlord and Tenant hereby acknowledge and agree that the Work Letter has been prepared jointly by both parties and that the Work Letter sets
forth the details of all improvements to be constructed by Landlord in the First Floor Premises prior to the Rent Commencement Date. 
 1.2 Landlord shall select such qualified, reputable and licensed general contractors and/or subcontractors as Landlord determines are appropriate in Landlord’s sole and absolute discretion for the construction of the First Floor
Tenant Improvements. Tenant shall reasonably cooperate with Landlord in the construction and supervision of the First Floor Tenant Improvements and shall not materially interfere with the same. 
 1.3 All First Floor Tenant Improvements shall be deemed Landlord’s property under the terms of the Lease and shall revert to Landlord upon
termination of the Lease for any reason, it being understood and agreed that Tenant shall have no ownership interest whatsoever in the First Floor Tenant Improvements. 
 1.4 As part of the First Floor Tenant Improvements, Landlord shall purchase from BMC the furniture, more particularly described on Schedule 2 attached hereto (“Purchased
Furniture”), in the First Floor Premises and Third Floor Premises. 
 1.5 Landlord shall cause the existing tenant to
leave the existing cabling and data communications wiring intact in the First Floor Premises and Third Floor Premises. 
 SECTION 2:
WORKING DRAWINGS 
 2.1 Landlord and Tenant hereby acknowledge the following that each intends that this Work Letter be
comprised of a budget, construction plans and specifications, drawings and details for build-out of the First Floor Premises in one (1) phase (collectively, the “Working Drawings”), which are attached hereto as Schedule
1 and are hereby approved by Landlord and Tenant. The Working Drawings shall not be changed without each party’s approval. Tenant agrees to respond to any written request from Landlord for Tenant’s approval of materials prepared to be
incorporated into the Working Drawings within five (5) business days from the date of any such request. Time shall be of the essence as to each of the timing provisions in this Work Letter. 

 SECTION 3: COMPLETION OF WORK 
 3.1 Landlord shall not be responsible to Tenant for any loss of or damage to any Tenant’s property installed or left in the First Floor
Premises or such other space within the Project during the completion of the First Floor Tenant Improvements or at any time thereafter during the entire Lease Term, except due to the gross negligence or willful misconduct of Landlord, or its
employees or agents. 
 3.2 Any additional out-of-pocket third party costs and expenses reasonably incurred by Landlord as a result of
any material breach by Tenant of the provisions of this Work Letter and/or any modifications requested by Tenant to the Working Drawings (and not otherwise required by law), including, without limitation, increased fees which Landlord may be
required to pay for architectural, engineering and other similar services, any additional construction costs, including costs of change orders, and any and all other out-of-pocket third party costs reasonably incurred or suffered by Landlord by
reason thereof, including any delays in Landlord’s construction of the First Floor Premises caused by Tenant’s failure to comply with the provisions of this Work Letter, shall be at the sole cost and expense of Tenant. 
 3.3 Tenant shall, at Tenant’s sole cost and expense, obtain all permits, licenses and other approvals required for Tenant’s particular
use of the First Floor Premises (other than relating to the construction of the First Floor Tenant Improvements). 
 3.4 As used in
the Lease or herein, the term “Substantial Completion,” “Substantially Completed,” and any derivations thereof mean the First Floor Tenant Improvements in the First Floor Premises is substantially
completed (as reasonably determined by Landlord’s contractor) in substantial accordance with the Working Drawings. 
 3.5 As used
herein, a “Tenant Delay Day” means each day of delay in the performance of the First Floor Tenant Improvements that occurs (a) because Tenant fails to timely furnish any information required hereunder or deliver or
approve any required documents in each case, as required by this Work Letter, (b) because of any change requested by Tenant to the Working Drawings (other than required by law); (c) because Tenant or its appointed agent or representative
fails to attend any meeting scheduled in advance at mutually acceptable times with Landlord, the architect, any design professional, or any contractor, or their respective employees or representatives, as may be required or scheduled hereunder or
otherwise necessary in connection with completion of the First Floor Tenant Improvements or (d) Tenant fails to deposit any Overage (as hereinafter defined) with Landlord as and when required hereunder. 
 3.6 Tenant shall have the right to conduct a walkthrough of the Premises with Landlord within fifteen (15) business days following the Rent
Commencement Date to establish a punch list of items (“Punch List Items”) to be completed by Landlord within thirty (30) days thereafter, provided, however, that if Landlord is unable, despite using its commercially
reasonable efforts to complete such Punch List Items within such thirty (30) day, then Landlord shall be afforded such additional time as is reasonably necessary to allow Landlord to complete such Punch List Items, provided that Landlord is
diligently prosecuting the same. The Punch List Items shall be limited to those components of the Tenant Improvements set forth in the Working Drawings which were not completed as of the Rent Commencement Date. 

 3.7 Landlord shall construct the First Floor Tenant Improvements in accordance with all applicable
Laws, in effect only, as of Substantial Completion of the First Floor Tenant Improvements. 
 SECTION 4: COST OF FIRST FLOOR TENANT
IMPROVEMENTS 
 4.1 Landlord anticipates that the costs to complete the First Floor Tenant Improvements will be Two Hundred
Fifty Five Thousand Two Hundred Nineteen and No/100 Dollars ($255,219.00) which does not include the cost of permits and any construction management fees (“Work Cost”) in total based on the Working Drawings. Landlord’s
obligations with respect to the First Floor Tenant Improvements (other than for permits and construction management fees, which shall remain Landlord’s obligation) shall not exceed the Work Cost. Tenant shall be responsible for the cost of the
First Floor Tenant Improvements to the extent they exceed the Work Cost (“Overage”). 

 Schedule 1 
 Working Drawings (together with Budget) 
 [Attached] 

 Schedule 2 
 Furniture to be Purchased and Installed in the Premises 
 5960 Inglewood Drive, Ste. 150 
 Inventory 1st & 3rd Floors 
  

							
	 Room/Location
	  	 Sell
	  	 Quantity
	  	 Notes

	1216	  	Teknion 30dx60w Ergotech Table w/ Black C-legs	  	2	  	
	1216	  	34.5wx41hx12.5d 2-shelf Black Metal Bookcase	  	1	  	
	1216	  		  		  	
	1216	  		  		  	
	1216	  	Highmark 1206 Task Chair	  	2	  	
	1216	  	Rubbermaid 3 shelf cart	  	1	  	
	1216	  	42 Round Side Table	  	1	  	
	1216	  		  		  	
	1216	  		  		  	
	1216	  	69.5wx83hx30d Storage shelves	  	2	  	
	1216	  		  		  	
	1216	  		  		  	
	1216	  	36 Round tale tops	  	3	  	
	1216	  	Teknion work surface	  	1	  	
	1216	  		  		  	
	1216	  		  		  	
	1216	  		  		  	
	1216	  		  		  	
	1216	  	Task chair w/ Arms, Blue	  	1	  	
	1217	  	30x60 Tables	  	4	  	
	1217	  	34.5wx41hx12.5d 2-shelf Black Metal Bookcase	  	2	  	
	1217	  		  		  	
	1217	  		  		  	
	1217	  		  		  	
	1217	  	Office Master Task Chairs High Back w/ arms Charcoal	  	1	  	
	1217	  	Highmark 1206 Task Chair	  	1	  	
	1217	  		  		  	
	1217	  	Stackable Charcoal chair	  	1	  	
	1217	  	86x87x23 Storage Shelf	  	1	  	
	1217	  	30dx72w Versteel Vela Folding table with Birch top, black legs	  	1	  	
	1217	  	36x21x72 2-door Gray Plastic Storage Cab	  	1	  	
	1217	  		  		  	
	1217	  		  		  	
	1218	  	Office Master Task Chairs High Back w/ arms Charcoal	  	2	  	
	1218	  	Highmark 1206 Task Chair	  	2	  	
	1218	  	Office Master Task Chairs w/ arms charcoal	  	2	  	

 5960 Inglewood Drive, Ste. 150 
 Inventory 1st & 3rd Floors 
  

							
	 Room/Location
	  	 Sell
	  	 Quantity
	  	 Notes

	1218	  	Task Chairs, Charcoal, reg. back w/ arms	  	1	  	
	1218	  		  		  	
	1218	  	Hon 4-drwr 52hx27d Putty File Cab	  	1	  	
	1218	  	34.5wx41hx12.5d 2-shelf Putty bookcase	  	1	  	
	1218	  		  		  	
	1218	  	51wx23dx41h Computer Display Cabinet	  	1	  	
	3105	  		  		  	
	3106	  	4-drwr Lateral Filing Cabinet	  	1	  	
	3106	  	69.5wx83hx30d Storage shelves	  	2	  	
	3107	  	Misc. Task Chairs	  	4	  	
	3107	  	30x60 Tables	  	1	  	
	3107	  	72x36x84 Metal Storage Shelf Gray	  	2	  	
	3107	  	69.5wx83hx30d Storage shelves	  	2	  	
	3107	  	Lab Bench w/ 2-shelves 27x36x84	  	4	  	
	3107	  	4-drwr Lateral Filing Cabinet	  	1	  	
	3107	  	3-drwr Vertical Filing Cabinet	  	1	  	
	3107	  	2-drwr Lateral Filing Cabinet	  	1	  	
	3107	  	27x85x32 Megaframe Cabinet	  	4	  	
	3121	  	60x22x34 Black Credenza	  	1	  	
	3121	  	5x12 Raceway Black Conf. Table w/ gold trim, 1 port	  	1	  	
	3121	  	Teknion Synopsis Conf. Chair	  	17	  	
	3121	  	30dx72w Versteel Vela Folding table with Birch top, black legs	  	3	  	
	3121	  	Built-in Projection screen	  	1	  	
	3121	  	72wx27d Gray Training Tables Black T-leg	  	1	  	
	3121	  	30dx72w Hon Table with dark gray legs on wheels	  	1	  	
	3200	  	66x30x63 Mail Slots & Storage Cab	  	1	  	
	3201	  	Office Master Task Chairs, High back w/ arms	  	2	  	
	3202	  	12x4 Rectangle Conf Table 1-port, Brown-Fleck	  	1	  	
	3202	  	Herman Miller Black Task Chair w/ arms	  	7	  	
	3202	  	21x96x30 Wood Credenza	  	1	  	
	3202	  		  		  	
	3202	  	Da-Lite Built-in Projection Screen	  		  	
	Augusta	  	Teknion Synopsis Conf. Chair	  	16	  	
	Augusta	  	60wx22dx34h 4-door black credenza	  	1	  	
	Augusta	  		  		  	
	Augusta	  		  		  	
	Augusta	  		  		  	
	Augusta	  		  		  	
	Augusta	  		  		  	
	Augusta	  		  		  	
	Augusta	  	Raceway Conference Table 14’x4’ Black with gold trim (3 ports)	  	1	  	

 5960 Inglewood Drive, Ste. 150 
 Inventory 1st & 3rd Floors 
  

							
	 Room/Location
	  	 Sell
	  	 Quantity
	  	 Notes

	Augusta	  	Office Master Task Chairs w/ arms charcoal	  	3	  	
	Augusta	  	Highmark 1206 Task Chair	  	1	  	
	Augusta	  		  		  	
	Augusta	  	4’hx8’w Whiteboard	  	1	  	
	Cubes	  	Misc. Task Chairs	  	30	  	
	Cubes	  	2-drwr lateral file cab - gray	  	2	  	
	Cubes	  	2-Shelf wood bookcase	  	1	  	
	Cubes	  	2-Shelf Metal Putty Bookcase	  	5	  	
	Cubes	  	As-is Cube Set Up: 2 straight surfaces, 1 corner surface, 1 overhead shelf, 1 closed shelf, 1 buddy seat, 1 box/File/File, 1 File/File, 1 task light, 1 whiteboard	  	90	  	4 of the 90 have some panels & parts missing
	Cubes	  	Misc. Cube Panels & Parts	  		  	
	Cubes	  	2-drwr vertical file cab, Black	  	1	  	
	Cubes	  	30dx72w Hon Table with dark gray legs on wheels	  	1	  	
	Cubes	  	3-shelf Metal bookcase, Black	  	1	  	
	Cubes	  	30dx72w Versteel Vela Folding table with Birch top, black legs	  	3	  	
	Cubes	  	1-shelf Metal Bookcase putty	  	1	  	
	Cubes	  	4-drwr Vertical filing cabinet, Black	  	3	  	
	Cubes	  	2-drwr vertical file cab, putty	  	2	  	
	Cubes	  	2-drwr Lateral file cab gray	  	2	  	
	Cubes	  	Misc. Task Chairs	  	44	  	
	Cubes	  	Misc. Guest Chairs	  	3	  	
	Cubes	  	2-shelf Metal Bookcase, Black	  	1	  	
	Cubes	  	2-drwr Lateral Filing Cabinet	  	1	  	
	Cubes	  	4-drwr Vertical filing cabinet, putty	  	2	  	
	Cubes	  	2-door Metal Storage Cabinet, gray	  	2	  	
	Cubes	  	2-door Metal Storage Cabinet, Black	  	1	  	
	Elevator lobby	  		  		  	
	Elevator lobby	  	30x30 Cube Table	  	1	  	
	Elevator lobby	  	20x20 Cube Table	  	1	  	
	Elevator Storage	  	Office Master Task Chairs w/ arms charcoal	  	5	  	
	Hall-Flr1	  		  		  	
	Hall-Flr1	  		  		  	
	Hall-Flr1	  		  		  	
	Hall-Flr1	  		  		  	
	Hall-Flr1	  		  		  	
	Hall-Flr1	  		  		  	
	Hall-Flr1	  		  		  	
	Hall-Flr1	  		  		  	
	Hall-Flr1	  		  		  	
	Hall-Flr1	  		  		  	
	Hall-Flr1	  		  		  	
	Hall-Flr1	  		  		  	

 5960 Inglewood Drive, Ste. 150 
 Inventory 1st & 3rd Floors 
  

							
	 Room/Location
	  	 Sell
	  	 Quantity
	  	 Notes

	Kitchen	  	Black Stackable Chair - Charcoal	  	8	  	
	Kitchen	  	Refrigerator/Freezer, White	  	1	  	
	Kitchen	  	60wx30d Tables	  	3	  	
	Offices	  	As-is Office Sets Standard: 2 tables, 1 File/File ped, 1 whiteboard, 1 Box/Box/File	  	16	  	
	Offices	  	2-shelf Metal Bookcase, Black	  	5	  	
	Offices	  	Misc. Guest Chairs	  	9	  	
	Offices	  	2-drwr Vertical Filing Cab putty	  	1	  	
	Offices	  	2-drwr lateral file cab - Black	  	2	  	
	Offices	  	Misc. Task Chairs	  	8	  	
	Offices	  	42” Round Table, Walnut Finish	  	1	  	
	Offices	  	2-drwr Vertical. File Cabinet, Black	  	1	  	
	Offices	  	Stackable Charcoal chair	  	11	  	
	Pebble Beach	  	36” Round Putty Table	  	1	  	
	Pebble Beach	  	36x29x77 2-door Metal Cabinet	  	1	  	
	Pebble Beach	  	72wx27d Gray Training Tables Black T-leg	  	1	  	
	Pebble Beach	  	30dx72w Versteel Vela Folding table with Birch top, black legs	  	16	  	
	Pebble Beach	  	4-drwr Lateral Filing Cabinet	  	1	  	
	Pebble Beach	  	Highmark Crayola Charcoal Stackable Chair	  	72	  	
	Pebble Beach	  		  		  	
	Pebble Beach	  	4’hx8’w Whiteboard	  	1	  	
	Pebble Beach	  	Easels	  	5	  	
	Pebble Beach	  		  		  	
	Pebble Beach	  	Da-Lite Built-in Projection screen	  	1	  	
	Phone Booths	  		  		  	
	Phone Booths	  	Herman Miller Black Task Chair w/ arms	  	4	  	
	Sierra	  	30dx72w Hon Table with dark gray legs on wheels	  	1	  	
	Sierra	  	24dx60w Bretford Adjustable table w/ Black C-legs	  	2	  	
	Sierra	  	72wx27d Gray Training Tables Black T-leg	  	18	  	
	Sierra	  	Brayton Technique Open Arm Black Leather Conf. Chairs, Chrome legs	  	6	  	
	Sierra	  		  		  	
	Sierra	  		  		  	
	Sierra	  	Office Master Task Chairs w/ arms charcoal	  	1	  	
	Sierra	  	Task Chairs, Charcoal, reg. back w/ arms	  	7	  	
	Sierra	  	Task Chairs, Charcoal, reg. back w/out arms	  	3	  	
	Sierra	  	Highmark 1206 Task Chair	  	2	  	
	Sierra	  		  		  	
	Sierra	  		  		  	
	Sierra	  	Wall clock	  	1	  	
	Sierra	  	Secretary Chair w/out arms	  	1	  	
	Sierra	  		  		  	
	Sierra	  	4’hx8’w Whiteboard	  	1	  	

 5960 Inglewood Drive, Ste. 150 
 Inventory 1st & 3rd Floors 
  

							
	 Room/Location
	  	 Sell
	  	 Quantity
	  	 Notes

	Sierra	  		  		  	
	Sierra	  		  		  	
	Tahoe	  	Office Master Task Chairs w/ arms charcoal	  	26	  	
	Tahoe	  	72wx27d Gray Training Tables Black T-leg	  	12	  	
	Tahoe	  	Black Leather Conf. Chair w/ arms	  	1	  	
	Tahoe	  	Teknion Buddy Seat Rolling ped	  	1	  	
	Tahoe	  		  		  	
	Tahoe	  		  		  	
	Tahoe	  	4’hx8’w Whiteboard	  	2	  	
	Tahoe	  	30dx72w Bretford Adjustable Table w/ Black C legs	  	1	  	
	Tahoe	  		  		  	
	Tahoe	  		  		  	
	Tahoe	  	Wall clock	  	1	  	
	Tahoe	  	30dx72w Versteel Vela Folding table with Birch top, black legs	  	1	  	
	Tahoe	  		  		  	
	Yosemite	  		  		  	
	Yosemite	  	Highmark 1206 Task Chair	  	17	  	
	Yosemite	  	72wx27d Gray Training Tables Black T-leg	  	8	  	
	Yosemite	  		  		  	
	Yosemite	  		  		  	
	Yosemite	  		  		  	
	Yosemite	  	Wall clock	  	1	  	
	Yosemite	  		  		  	
	Yosemite	  	4’hx8’w Whiteboard	  	1	  	
	Yosemite	  	Teknion Buddy Seat Rolling ped	  	1	  	
	Yosemite	  	90wx64h Da-Lite Electric Built-in Projection Screen	  	1	  	
	Yosemite	  		  		  	
	3117	  	4x12 Raceway Conf, Table Black w/ gold trim 1 port	  	1	  	
	3117	  	Brayton Conf. Room Chairs - Tan/Gray Floral	  	5	  	
	3117	  	4’hx8’w Whiteboard	  	1	  	
	3117	  		  		  	

 EXHIBIT B-2 
 THIRD FLOOR TENANT IMPROVEMENTS 
 Tenant accepts the Third Floor Premises in its As-Is condition,
except that Landlord shall cause: (a) the carpets shall be professionally cleaned and (b) the walls shall be patched and painted (collectively, the “Third Floor Tenant Improvements”), in each case, prior to the Rent
Commencement Date. 

 EXHIBIT C 
 OCCUPANCY ESTOPPEL CERTIFICATE 
 THIS OCCUPANCY ESTOPPEL CERTIFICATE
(“Certificate”) is given by ADEPT TECHNOLOGY, INC., a Delaware corporation (“Tenant”) to PARK LAKE APARTMENTS, L.P., a California limited partnership (“Landlord”), with respect
to that certain Lease Agreement dated September     , 2008 (“Lease”), under which Tenant has leased from Landlord certain premises (“Premises”) in the building located at
5960 Inglewood Drive, Pleasanton, California (“Building”). 
 In consideration of the mutual covenants and agreements stated in the
Lease, and intending that this Certificate may be relied upon by Landlord and any prospective purchaser or present or prospective mortgagee, deed of trust beneficiary or ground lessor of all or a portion of the Building, Tenant certifies as follows:

 1. Except for those terms expressly defined in this Certificate, all initially capitalized terms will have the meanings stated for such
terms in the Lease. 
 2. Landlord fast delivered possession of the Premises to Tenant with the Tenant Improvements Substantially Completed
on                     ,         . 
 3. The Rent Commencement Date occurred on
                    ,         , and the Expiration Date will occur on
                    ,         . 
 Executed this      day of
                    ,         . 
  

			
	TENANT:
		
	By:	 	  

	Name:	 	  

	Title:	 	  

		
	By:	 	  

	Name:	 	  

	Title:	 	  

 The authorized officers of Tenant must sign on behalf of the corporation and indicate the capacity in which
they are signing. This document must be executed by the president or vice-president and the secretary or assistant secretary, unless the bylaws or a resolution of the board of directors shall otherwise provide, in which event, the bylaws or a
certified copy of the resolution, as the case may be, must be attached to this document. 

 EXHIBIT D 
 RULES AND REGULATIONS 
 1. Tenant shall not place anything or allow anything to be placed near the
glass of any window, door, partition or wall, which may in Landlord’s reasonable judgment appear unsightly from outside the Premises or from outside the Building. 
 2. The sidewalks, halls, passages, exits, entrances, elevators and stairways shall not be obstructed by Tenant for any purposes other than for ingress to and egress from the Premises. The halls, passages, exits,
entrances, elevators, stairways, balconies and roof are not for the use of the general public and the Landlord shall in all cases retain the right to control and prevent access thereto by all persons whose presence in the judgment of Landlord,
reasonably exercised, shall be prejudicial to the safety, character, reputation and interests of the Building. Neither Tenant nor any employees or invitees of any tenant shall go upon the roof of the Building. 
 3. The toilet rooms, urinals, wash bowls and other apparatus shall not be used for any purposes other than that for which they were constructed and no
foreign substance of any kind whatsoever shall be thrown therein, and to the extent caused by Tenant or its employees or invitees, the expense of any breakage, stoppage or damage resulting from the violation of this rule shall be borne by Tenant
unless covered or required to be covered by Landlord’s property insurance required to be maintained under this Lease; however, if any such breakage, stoppage or damage is so covered or required to be covered, Tenant shall nevertheless be
responsible up to the deductible amount (not to exceed $5,000). 
 4. Tenant shall not cause any unnecessary janitorial labor or services to
the Common Areas by reason of Tenants carelessness or indifference in the preservation of good order and cleanliness. 
 5. Unless otherwise
permitted in the lease, no cooking shall be done or permitted by Tenant on the Premises except in the outdoor barbeque area. The Premises shall not be used for lodging. Landlord and Tenant acknowledge that Tenant shall be permitted to use the
outdoor barbeque area for cooking and grilling. In addition, Tenant may from time to time in connection with events in the outdoor barbeque area use a portion of the parking lot near the east side of the building for barbequing and cooking.

 6. Tenant shall not bring upon, use or keep in the Premises or the Building any kerosene, gasoline or flammable or combustible fluid or
material, except as may be necessary in connection with any back-up power supply installed by Tenant pursuant to the lease or other equipment in the Premises or on the Project and any cleaning supplies. Tenant shall not use any method of heating the
Premises other than that supplied by Landlord. 
 7. Tenant shall not allow any of its owners, employees, agents, visitors, clients or
invitees to smoke in the Premises or the Building. Tenant shall be entitled to designate a smoking area for its employees outside the Building subject to Landlord’s approval of the location thereof. 

 8. Landlord shall have sole power to direct electricians as to where and how telephone and other wires
are to be introduced. No boring or cutting for wires is to be allowed without the consent of Landlord. The location of telephones, call boxes and other office equipment affixed to the Premises shall be subject to the approval of Landlord.
Landlord’s approval of plans and specifications that reflect the necessity for boring or cutting and/or the locations of telephones, call boxes and other office equipment affixed to the Premises shall be deemed consent or approval, as
applicable, of the same and the location thereof. 
 9. Upon the termination of the tenancy, Tenant shall deliver to the Landlord all keys
and passes for offices, rooms, parking lot and toilet rooms which shall have been furnished by Landlord. In the event of the loss of any keys so furnished, Tenant shall pay the Landlord for a like number of replacement keys if Landlord is required
to replace the same. Tenant shall not make or cause to be made any such keys and shall order all such keys solely from Landlord and shall pay Landlord for Landlord’s actual out-of-pocket cost of providing any additional such keys over and above
the two sets of keys furnished by Landlord. 
 10. Tenant shall not install linoleum, tile, carpet or other floor covering so that the same
shall be affixed to the floor of the Premises in any manner except as approved by Landlord. 
 11. Tenant shall use reasonable efforts to
cause all doors to the Premises to be closed and securely locked before leaving the Building at the end of the day. 
 12. Landlord and
Tenant shall cooperate with each other to ensure effective operation of the Premises and the Building’s heating and air conditioning, and shall refrain from attempting to adjust any controls; however, Tenant shall be entitled to make minor
adjustments in the thermostats for the Premises so as to maintain comfortable temperature conditions in the Premises and to adjust controls in emergency situations. Landlord shall promptly respond to calls from Tenant requesting adjustment of any
controls. Tenant shall keep corridor doors between the Premises and Common Areas closed. 
 13. Tenant shall be primarily responsible for
protecting the Premises from theft, robbery and pilferage, which includes keeping doors locked and other means of entry to the Premises closed and secured. 
 14. Peddlers, solicitors and beggars shall be reported to the office of the Building or as Landlord otherwise requests in writing. 
 15. Tenant shall not advertise the business, profession or activities of Tenant conducted in the Building in any manner which violates any code of ethics adopted by any recognized association or organization of which
Tenant is a member pertaining to such business, profession or activities. 
 16. Tenant may not allow pets to be brought into the Building or
any part thereof except for seeing eye dogs. 

 17. Tenant acknowledges that Building security problems may occur which may require the employment of
extreme security measures in the day-to-day operation of the Building. However, Landlord agrees that such security measures shall be reasonable in light of the circumstances for a building such as the Building. Landlord shall not employ any such
security measures for purposes of harassment or disruption of Tenant’s business, its employees or Tenant’s invitees. 
 Accordingly: 
 (a) Landlord may at any time, or from time to time, or for regularly scheduled time periods, as
deemed advisable by Landlord and/or its agents, in their reasonable discretion, require that persons entering or leaving the Building identify themselves to watchmen or other employees designated by Landlord, by registration, identification or
otherwise. 
 (b) Landlord may at any time, or from time to time, or for regularly scheduled time periods, as deemed advisable
by Landlord and/or its agents, in their reasonable discretion, employ other reasonable security measures, such as, but not limited to, the search parcels, packages, etc., entering and leaving the Building, the evacuation of the Building, and the
denial of access of any person to the Building. 
 (c) Tenant hereby assents to the exercise of the above discretion by
Landlord and its agents, so long as such discretion is exercised under reasonable belief of cause regardless of whether or not such action shall in fact be warranted, and so long as any such action is applied uniformly or is aimed at specific
persons whose conduct is deemed suspicious. 
 (d) To the extent such security measures are reasonable for a building such as
the Building in light of the circumstances necessitating such security measures, the exercise of such security measures and the resulting interruption of service and cessation or loss of Tenant’s business, if any, shall never be deemed an
eviction or disturbance of Tenant’s use and possession of the Premises, or any part thereof, or render Landlord liable to Tenant for damages or relieve Tenant from Tenant’s obligations under this Lease. 
 (e) Tenant agrees that it and its employees will reasonably cooperate with Building employees in the implementation of any and all
security procedures to the extent such security measures are reasonable for a building such as the Building in light of the circumstances. 
 (f) Such security measures shall be the sole responsibility of Landlord and Tenant shall have no liability for action taken by Landlord in connection therewith. 
 To the extent reasonably possible, Landlord shall minimize the disruption to, and shall not employ any such security measures for purposes of harassment or disruption
of, Tenant’s business, its employees or Tenant’s invitees. 

 21. Canvassing, soliciting or peddling in the Building is prohibited and Tenant shall cooperate to
prevent same. 
 22. Tenant shall not make or permit any loud or improper noises in the Premises or the Building or otherwise unreasonably
interfere in any way with other tenants in the Building. Landlord acknowledges, however, that the foregoing shall not diminish Tenant’s rights to hold outdoor events on the Project as permitted under the Lease. 
 23. Tenant, or the employees, agents, servants, visitors or licensees of Tenant, shall not, at any time or place, leave or discard rubbish, paper,
articles or objects of any kind whatsoever outside the doors of the Premises or in the corridors or passageways of the Building except in approved trash receptacles. 
 24. Landlord shall have the right to reasonably determine and prescribe the weight and proper position of any unusually heavy equipment, including computers, safes, large files, etc., that are to be placed in the
Building, and only those which in the reasonable judgment of the Landlord will not do damage to the floors, structure and/or elevators may be moved into the Building. Any damage caused by installing, moving or removing such aforementioned articles
in the Building shall be paid for by Tenant. 
 25. The requirements of Tenant will be attended to only upon application at the office of the
Building. Except as otherwise provided in the Lease, employees of Landlord and service contractors shall not perform any work for tenants outside of their regular duties, unless under special instructions form the office of the Building. 

26. Landlord reserves the right to modify, amend or rescind any of these Rules and Regulations of the Building, and to make such other and further
rules and regulations as in its judgment shall from time to time be needed for the safety, protection, care and cleanliness of the Building, the Leased Premises, the preservation of good order therein and the protection and comfort of the tenants in
the Building and their agents, employees and invitees, which rules and regulations when modified, amended or made and written notice thereof is given to Tenant, shall be binding upon Tenant in like manner as if originally herein prescribed, subject
to the limitations set forth in the Lease. As provided in the Lease, to the extent any inconsistency exists or arises between these Rules and Regulations and the provisions of the Lease, the provisions of the Lease shall control. 

 EXHIBIT E 
 PARKING 
 1. PARKING SPACES. Landlord shall provide to Tenant for its non-exclusive use during
the Term four (4) parking spaces per 1,000 Rentable Square Feet in the Premises from time to time in the parking facilities on the Land (the “Parking Facilities”). 
 2. NO PARKING CHARGES: During the Term, all parking spaces shall be provided to Tenant at no additional charge. 
 3. USE: Tenant’s parking spaces will be for the use of employees only (“Patron”), except that Tenant may permit a
portion of its spaces in the Parking Facilities to be designated as assigned visitor spaces for use by Tenant’s invitees. Patrons will be granted access to the parking facilities only upon the signing of a parking license with Landlord if
desired by Landlord and requested in a written notice to Tenant. Tenant agrees to abide by Landlord’s reasonable parking rules and regulations adopted from time to time which shall be applied uniformly and without discrimination. 
 4. DISCLAIMER: The Parking Facilities only provide a license to park at Tenant’s sole risk. No bailment is created. Landlord does not provide
safekeeping, nor shall it be deemed an insurer for vehicles or their contents. Landlord will not be responsible for fire, theft, damage or loss. 
 5. DAMAGE TO OR CONDEMNATION OF PARKING FACILITIES: If Landlord fails or is unable to provide any parking space to Tenant in the Parking Facilities because of damage or condemnation, such failure or inability shall never be deemed to
be a default by Landlord as to permit Tenant to terminate the Lease, either in whole or in part. 
 6. VIOLATION OF RULES: Landlord
may refuse to permit any person who violates the rules for the Parking Facilities to park in the Parking Facilities and any violation of the rules shall subject the car to removal at the car owner’s expense. No such refusal or removal shall
create any liability on Landlord or be deemed to interfere with Tenant’s right to quiet possession of the Premises. 

 EXHIBIT F 
 EXPENSE EXCLUSIONS 
 Expenses will not include: 
 (1) payments of principal, finance charges or interest on debt or amortization on any mortgage, deed of trust or other debt and rental payments (or
increases in same) under any ground or underlying lease or leases; 
 (2) advertising and promotional expenses directly relating to leasing;

 (3) costs for which Landlord is entitled to be reimbursed by insurance proceeds or from tenants of the Building (other than such
tenants’ regular contributions to Expenses); 
 (4) any depreciation or capital expenditures (except as expressly provided in the
definition of Expenses); 
 (5) legal fees incurred for negotiating leases or collecting rents; 
 (6) costs directly and solely related to the maintenance and operation of the entity that constitutes the Landlord, such as accounting fees incurred
solely for the purpose of reporting Landlord’s financial condition; 
 (7) costs of repairs, replacements or other work occasioned by
fire, windstorm or other casualty if insured, or the exercise by governmental authorities of the right of eminent domain; 
 (8) leasing
commissions, attorney’s fees, costs, disbursements and other expenses incurred by Landlord or its agents in connection with negotiations for leases with tenants, other occupants or prospective tenants or other occupants of the Building, and
similar costs incurred in connection with disputes with and/or enforcement of any leases with tenants, other occupants, or prospective tenants or other occupants of the Building; 
 (9) “Tenant or tenant allowances,” “Tenant or tenant concessions,” and other costs and expenses (including permit, license and
inspection fees) incurred in connection with completing, fixturing furnishing, renovating or otherwise improving, decorating or redecorating space for tenants or other occupants of the Building, or vacant, leasable space in the Building, including
space planning/interior architecture fees and/or engineering for same; 
 (10) services, items and benefits for which Tenant or any other
tenant or occupant of the Building specifically reimburses Landlord or for which Tenant or any other tenant or occupant of the Building pays third persons; 
 (11) costs or expenses (including fines, penalties and legal fees) incurred due to the violation by Landlord, its agents, any tenant (other than Tenant) or other occupant of the 

 
Building, of any terms and conditions of this Lease or of the leases of other tenants in the Building, and/or of any valid, applicable Laws that would not
have been incurred but for such violation by Landlord, its agents, or tenants, it being intended that each party shall be responsible for the costs resulting from its violation of such leases and Laws; 
 (12) penalties for any late payment, including, without limitation, taxes, equipment leases, etc.; 
 (13) costs directly resulting from the active negligence or willful misconduct of Landlord or its agents; 
 (14) compensation paid to clerks, attendants or other persons in commercial concessions (such as a snack bar, restaurant or newsstand) in which such
person’s services are not available to Tenant; 
 (15) contributions to operating expense reserves; 
 (16) premiums and other charges with respect to rental loss insurance for any period in excess of 12 months; 
 (17) Landlord’s contributions to charitable organizations; 
 (18) costs incurred in removing the property of former tenants and or occupants of the Building (excluding normal trash removal); 
 (19) costs or fees relating to the defense of Landlord’s title to or interest in the Building, Land or any part thereof; 
 (20) costs of correcting design or construction defects, including any allowances for same, in the construction of the Building (including latent defects) or any associated parking facilities, or other improvements;

 (21) payments in respect of overhead and/or profit of any subsidiary or Affiliate of Landlord, or to any other party, as a result of a
non-competitive selection process for services (other than the management fee, as provided hereinabove) on or to the Building, or for goods, supplies or other materials, to the extent that the costs of such services, goods, supplies and/or materials
materially exceed the costs that would have been paid had such services, goods, supplies or materials been provided (in the same manner, at the same time and upon the same terms and conditions) by parties who are not Affiliates, of similar skill,
competence and experience, on a competitive basis; 
 (22) any franchise or income taxes of Landlord; 
 (23) rentals and other related expenses, if any, incurred in leasing air-conditioning systems, elevators or other equipment ordinarily considered to be
of a capital nature, except equipment which is used in providing janitorial services or occasional conventional repairs or maintenance and which is not affixed to the Building; 

 (24) costs incurred in installing, operating, maintaining and owning any specialty items or services not
normally installed operated and maintained in Buildings comparable to the Building and not necessary for Landlord’s operation, repair and maintenance of, and the providing of required services for, the Building, including, but not limited to,
any observatory, beacon(s), broadcasting facilities, luncheon club, athletic or recreational club, child care center, concierge, kiosks, promotions, displays, etc; 
 (25) costs or expenses for sculpture, paintings or other works of art, including costs incurred with respect to the purchase, ownership, leasing, showing, promotion, securing, repair and/or maintenance of same, other
than normal building decorations customary in buildings comparable to the Building; 
 (26) consulting costs and expenses incurred by
Landlord except to the extent same are reasonable and relate exclusively to the management or operation of the Land and/or Building; 
 (27)
costs or expenses for maintenance and repair of the structural portions of the Building, including the roof structure, floor slabs, foundation, structural walls, the electrical transformer and electrical system up to and including the distribution
panels, and costs and expenses of replacing (as opposed to repairing or maintaining) all underground utilities, including sewer and water mains; 
 (28) costs for electrical service provided to the Project (as Tenant is to pay for electrical for the Project to the extent provided in Section 7.3 of the Lease); 
 (29) costs for janitorial service provided to the Premises at Tenant’s direct cost; 
 (30) costs for janitorial service provided to the premises of other tenants in the Building; 
 (31) costs to correct any non-compliance existing as of the date hereof of any Laws at the Project or any portion thereof; and 
 (32) costs to comply with any requirement under the ADA if such compliance requirement is triggered as a result of improvements to be performed by
Landlord for a particular tenant in the Project. 

 EXHIBIT G 
 Form of Subordination, Non-Disturbance and Attornment Agreement 
 RECORDING REQUESTED BY AND 
 AFTER RECORDING, RETURN TO: 
  
  
 SPACE ABOVE THIS LINE RESERVED FOR
RECORDER’S USE 
 SUBORDINATION, NON-DISTURBANCE 
 AND ATTORNMENT AGREEMENT 
 This Subordination, Non-Disturbance and Attornment
Agreement (“Agreement”), is made as of this      day of                     ,
200   among
                                         
                                , its successors, assigns and affiliates
(“Lender”),                                 , a
                                 (“Landlord”)
                            , and
                                , a
                                 (“Tenant”). 
 Background 
 Lender has made a
loan to Landlord in the original principal amount $                     (“Loan”), which is or will be secured by a mortgage,
deed of trust or similar security instrument (either, “Security Instrument”) on Landlord’s property described more particularly on Exhibit A attached hereto (“Property”). 
 Tenant is the present lessee under that certain lease agreement between Landlord and Tenant dated
                    , as thereafter modified and supplemented (“Lease”), demising a portion of the Property described more
particularly in the Lease (“Leased Space”). 
 A requirement of the Loan is that Tenant’s Lease be subordinated to the
Security Instrument. Landlord has requested Tenant to so subordinate the Lease in exchange for Lender’s agreement not to disturb Tenant’s possession of the Leased Space upon the conditions set forth in this Agreement. 
 NOW, THEREFORE, in consideration of the mutual promises of this Agreement, and intending to be legally bound hereby, the parties hereto agree as follows:

 1. Subordination. Subject to the terms hereof, and provided Lender complies with its obligations hereunder, Tenant agrees that the
Lease, and all estates, options and rights created under the Lease, hereby are subordinated and made subject to the lien and effect of the Security Instrument, as if the Security Instrument had been executed and recorded prior to the Lease. This
Agreement is not intended and shall not be construed to subordinate the Lease to any other liens or instruments other than the Security Instrument. 
 2. Nondisturbance. Lender agrees that no foreclosure (whether judicial or nonjudicial), deed-in-lieu of foreclosure, or other sale of the Property in connection with 

 
enforcement of the Security Instrument or otherwise in satisfaction of the Loan shall operate to terminate the Lease or Tenant’s rights thereunder to
possess and use the Leased Space and Tenant shall not be named as a party therein unless Lender is legally required to do so in order to proceed with foreclosure, and in any event any such foreclosure shall be subject to the terms of this Agreement;
provided, however, such joinder shall not result in the termination of the Lease or Tenant’s rights thereunder to possess and use the leased space and Lender hereby recognizes Tenant’s rights in and to the Leased Space under the Lease; and
the sale of the Property in any such action or proceeding and the exercise by Lender of any of its other rights under the Note, the Security Instrument or any of the other Loan Documents (as defined in the Security Instrument) shall be made subject
to all rights of Tenant under the Lease, provided, however, that (a) the term of the Lease has commenced, (b) Tenant is in possession of the Leased Space, and (c) the Lease is in full force and effect and no uncured default exists
under the Lease beyond any applicable cure periods under any of the terms, covenants or conditions of the Lease on Tenant’s part to be observed or performed. 
 3. Attornment. Tenant agrees to attorn to and recognize as its landlord under the Lease each party acquiring legal title to the Property by foreclosure (whether judicial or nonjudicial) of the Security
Instrument, deed-in-lieu of foreclosure, or other sale in connection with enforcement of the Security Instrument or otherwise in satisfaction of the Loan (“Successor Owner”). Provided that the conditions set forth in Section 2
above are met at the time Successor Owner becomes owner of the Property, the Lease shall not be terminated or affected thereby but shall continue in full force and effect as a direct lease between Successor Owner and Tenant upon all of the terms,
covenants and conditions set forth in the Lease and Successor Owner shall assume and be bound to Tenant to perform the obligations of Landlord under the Lease, and in that event, Tenant agrees to attorn to Successor Owner and Successor Owner by
virtue of such acquisition of the Property shall be deemed to have agreed to accept such attornment. Successor Owner shall perform all obligations of the landlord under the Lease arising from and after the date title to the Property is transferred
to Successor Owner. In no event, however, will any Successor Owner be: (a) liable for any default, act or omission of any prior landlord under the Lease except that (i) Successor Owner shall not be relieved from the obligation to cure any
defaults which are non-monetary and continuing in nature and such that Successor Owner’s failure to cure the same, from and after the date title to the Property is transferred to Successor Owner, would constitute a continuing default under this
Lease; (b) subject to any offset or defense which Tenant may have against any prior landlord under the Lease unless such sums are actually received by Successor Owner (it being understood and agreed that Successor Owner shall be subject to any
offsets, defenses, abatements or counterclaims first arising under the Lease from and after the date of such acquisition of the Property by Successor Owner); (c) bound by any payment of rent or additional rent made by Tenant to Landlord more
than 30 days in advance unless such sums are actually received by Successor Owner; (d) bound by any agreement terminating or amending or modifying the rent, term, commencement date or other material terms of the Lease, made without
Lender’s prior written consent prior to the time Successor Owner succeeded to Landlord’s interest or (e) liable for the return of any security deposit or other prepaid charge paid by Tenant under the Lease, except to the extent such
amounts were actually received by Successor Owner. Although the foregoing provisions of this Agreement are self-operative, Tenant agrees to execute and deliver to Lender or any Successor Owner such further instruments as Lender or a Successor Owner
may from time to time request 

 
in order to confirm this Agreement; provided, however, that no such instrument shall increase Tenant’s liability or obligations or decrease
Tenant’s rights under this Agreement or the Lease (as modified hereby) other than in de minimis respects. If any liability of Successor Owner does arise pursuant to this Agreement, such liability shall be limited to Successor Owner’s
interest in the Property. 
 4. Rent Payments; Notice to Tenant Regarding Rent Payments. Tenant agrees not to pay rent more than one
(1) month in advance unless otherwise specified in the Lease. After written notice is given to Tenant by Lender that Landlord is in default under the Security Instrument and that the rentals under the Lease are to be paid to Lender directly
pursuant to the assignment of leases and rents granted by Landlord to Lender in connection therewith (which notice shall include payment instructions for Lender’s account), Tenant shall thereafter pay to Lender all rent and all other amounts
due or to become due to Landlord under the Lease. Landlord hereby expressly authorizes Tenant to make such payments to Lender upon reliance on Lender’s written notice (without any inquiry into the factual basis for such notice or any prior
notice to or consent from Landlord) and hereby discharges and releases Tenant from all liability to Landlord in connection with Tenant’s compliance with Lender’s written instructions. 
 5. Lender Opportunity to Cure Landlord Defaults. Tenant agrees that, until the Security Instrument is released by Lender, it will not exercise any
remedies under the Lease following a Landlord default without having first given to Lender (a) written notice of the alleged Landlord default and (b) the opportunity to cure such default within the longer of (i) 30 days after the cure
period provided under the Lease to Landlord, (ii) 30 days from Landlord’s receipt of Tenant’s notice to Lender of a Landlord default, or (iii) if the cure of such default requires possession of the Property, 30 days after Lender
has obtained possession of the Property; provided that, in each case, if such default cannot reasonably be cured within such 30-day period and Lender has diligently commenced to cure such default promptly within the time contemplated by this
Agreement, such 30-day period shall be extended for so long as it shall require Lender, in the exercise of due diligence, to cure such default, but, unless the parties otherwise agree, in no event shall the entire cure period be more than 120 days.
Tenant acknowledges that Lender is not obligated to cure any Landlord default, but if Lender elects to do so, Tenant agrees to accept cure by Lender as that of Landlord under the Lease and will not exercise any right or remedy under the Lease for a
Landlord default. Performance rendered by Lender on Landlord’s behalf is without prejudice to Lender’s rights against Landlord under the Security Instrument or any other documents executed by Landlord in favor of Lender in connection with
the Loan. 
 6. Miscellaneous. 
 6.1 Notices. All notices and other communications under this Agreement are to be in writing and addressed as set forth below such party’s signature hereto. Default or demand notices shall be deemed to have been duly given upon
the earlier of: (i) actual receipt; (ii) one (1) business day after having been timely deposited for overnight delivery, fee prepaid, with a reputable overnight courier service, having a reliable tracking system; (iii) one
(1) business day after having been sent by telecopier (with answer back acknowledged) provided an additional notice is given pursuant to (ii); or (iv) three (3) business days after having been 

 
deposited in any post office or mail depository regularly maintained by the U.S. Postal Service and sent by certified mail, postage prepaid, return receipt
requested, and in the case of clause (ii) and (iv) irrespective of whether delivery is accepted. A new address for notice may be established by written notice to the other parties; provided, however, that no address change will be
effective until written notice thereof actually is received by the party to whom such address change is sent. 
 6.2 Entire Agreement;
Modification. This Agreement is the entire agreement between the parties hereto with respect to the subject matter hereof, and supersedes and replaces all prior discussions, representations, communications and agreements (oral or written). This
Agreement shall not be modified, supplemented, or terminated, nor any provision hereof waived, except by a written instrument signed by the party against whom enforcement thereof is sought, and then only to the extent expressly set forth in such
writing. 
 6.3 Binding Effect; Joint and Several Obligations. This Agreement is binding upon and inures to the benefit of the parties
hereto and their respective heirs, executors, legal representatives, successors, and assigns, whether by voluntary action of the parties or by operation of law. 
 6.4 Unenforceable Provisions. Any provision of this Agreement which is determined by a court of competent jurisdiction or government body to be invalid, unenforceable or illegal shall be ineffective only to the
extent of such determination and shall not affect the validity, enforceability or legality of any other provision, nor shall such determination apply in any circumstance or to any party not controlled by such determination. 
 6.5 Duplicate Originals; Counterparts. This Agreement may be executed in any number of duplicate originals, and each duplicate original shall be
deemed to be an original. This Agreement (and each duplicate original) also may be executed in any number of counterparts, each of which shall be deemed an original and all of which together constitute a fully executed Agreement even though all
signatures do not appear on the same document. 
 6.6 Construction of Certain Terms. Defined terms used in this Agreement may be used
interchangeably in singular or plural form, and pronouns shall be construed to cover all genders. Article and section headings are for convenience only and shall not be used in interpretation of this Agreement. The words “herein,”
“hereof” and “hereunder” and other words of similar import refer to this Agreement as a whole and not to any particular section, paragraph or other subdivision; and the word “section” refers to the entire section and
not to any particular subsection, paragraph or other subdivision; and “Agreement” and each of the Loan Documents referred to herein mean the agreement as originally executed and as hereafter modified, supplemented, extended,
consolidated, or restated from time to time. 
 6.7 Governing Law. This Agreement shall be interpreted and enforced according to the
laws of the State where the Property is located (excluding any choice of law rules that may direct the application of the laws of another jurisdiction). 

 6.8 Consent to Jurisdiction. Each party hereto irrevocably consents and submits to the exclusive
jurisdiction and venue of any state or federal court sitting in the county and state where the Property is located with respect to any legal action arising with respect to this Agreement and waives all objections which it may have to such
jurisdiction and venue. 
 6.9 WAIVER OF JURY TRIAL. TO THE FULLEST EXTENT PERMITTED BY LAW, EACH PARTY HERETO WAIVES AND AGREES NOT
TO ELECT A TRIAL BY JURY WITH RESPECT TO ANY ISSUE ARISING OUT OF THIS AGREEMENT. 

 Having read and intending to be bound by the terms and provisions of this Lease, Landlord and Tenant have signed it as of
the Date. 
  

					
	TENANT:	 	ADEPT TECHNOLOGY, INC.,
		 	a Delaware corporation
			
		 	By:	 	 /s/ John Dulchinos

		 	Name:	 	John Dulchinos
		 	Its:	 	President and Chief Executive Officer
			
		 	By:	 	 /s/ Lisa Cummins

		 	Name:	 	Lisa Cummins
		 	Its:	 	CFO
		
	LANDLORD:	 	PARK LAKE APARTMENTS, L.P.,
		 	a California limited partnership
			
		 	By:	 	 /s/ Carlos Zocchi

		 	Name:	 	Carlo Zocchi
		 	Its:	 	General Partner

 The authorized officers of Tenant must sign on behalf of the corporation and indicate the capacity in which they
are signing. The Lease must be executed by the president or a vice-president and the secretary or an assistant secretary, unless the bylaws or a resolution of the board of directors shall otherwise provide, in which event, the bylaws or a certified
copy of the resolution, as the case may be, must be attached to this Lease.

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00149-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00149-of-00352.parquet"}]]