Document:

EX-10.12

 Exhibit 10.12 
 STANDARD OFFICE LEASE 
 BY AND BETWEEN 

ARDEN REALTY LIMITED PARTNERSHIP, 
 a Maryland limited partnership, 
 AS LANDLORD, 

AND 

VITAL THERAPIES, INC., 
 a Delaware corporation, 
 AS TENANT 

SUITES 150 & 200 
 Carmel Point 

 TABLE OF CONTENTS 

 

							
	 	  	 	  	Page	 
	 ARTICLE 1
	  	BASIC LEASE PROVISIONS	  	 	1	  
			
	 ARTICLE 2
	  	TERM/PREMISES	  	 	2	  
			
	 ARTICLE 3
	  	RENTAL	  	 	2	  
	             (a)
	  	Basic Rental	  	 	2	  
	             (b)
	  	Increase in Direct Costs	  	 	2	  
	             (c)
	  	Definitions	  	 	3	  
	             (d)
	  	Determination of Payment	  	 	5	  
	             (e)
	  	Audit Right	  	 	6	  
			
	 ARTICLE 4
	  	CASH SECURITY DEPOSIT/LETTER OF CREDIT	  	 	7	  
	             (a)
	  	Cash Security Deposit	  	 	7	  
	             (b)
	  	Letter of Credit	  	 	7	  
			
	 ARTICLE 5
	  	HOLDING OVER	  	 	9	  
			
	 ARTICLE 6
	  	OTHER TAXES	  	 	10	  
			
	 ARTICLE 7
	  	USE	  	 	10	  
			
	 ARTICLE 8
	  	CONDITION OF PREMISES	  	 	10	  
			
	 ARTICLE 9
	  	REPAIRS AND ALTERATIONS	  	 	11	  
	             (a)
	  	Landlord’s Obligations	  	 	11	  
	             (b)
	  	Tenant’s Obligations	  	 	11	  
	             (c)
	  	Alterations	  	 	11	  
	             (d)
	  	Insurance; Liens	  	 	12	  
	             (e)
	  	Costs and Fees; Removal	  	 	12	  
			
	 ARTICLE 10
	  	LIENS	  	 	12	  
			
	 ARTICLE 11
	  	PROJECT SERVICES	  	 	13	  
	             (a)
	  	Basic Services	  	 	13	  
	             (b)
	  	Excess Usage	  	 	13	  
	             (c)
	  	Additional Electrical Service	  	 	13	  
	             (d)
	  	HVAC Balance	  	 	13	  
	             (e)
	  	Telecommunications	  	 	14	  
	             (f)
	  	After-Hours Use	  	 	14	  
			
	 ARTICLE 12
	  	RIGHTS OF LANDLORD	  	 	14	  
	             (a)
	  	Right of Entry	  	 	14	  
	             (b)
	  	Maintenance Work	  	 	14	  
	             (c)
	  	Rooftop	  	 	15	  
			
	 ARTICLE 13
	  	INDEMNITY; EXEMPTION OF LANDLORD FROM LIABILITY	  	 	15	  
	             (a)
	  	Indemnity	  	 	15	  
	             (b)
	  	Exemption of Landlord from Liability	  	 	15	  
	             (c)
	  	Security	  	 	15	  
			
	 ARTICLE 14
	  	INSURANCE	  	 	15	  
	             (a)
	  	Tenant’s Insurance	  	 	15	  
	             (b)
	  	Form of Policies	  	 	16	  
	             (c)
	  	Landlord’s Insurance	  	 	16	  
	             (d)
	  	Waiver of Subrogation	  	 	16	  
	             (e)
	  	Compliance with Insurance Requirements	  	 	17	  
			
	 ARTICLE 15
	  	ASSIGNMENT AND SUBLETTING	  	 	17	  
			
	 ARTICLE 16
	  	DAMAGE OR DESTRUCTION	  	 	19	  

  
 (i)

							
	 	  	 	  	Page	 
	 ARTICLE 17
	  	SUBORDINATION	  	 	20	  
			
	 ARTICLE 18
	  	EMINENT DOMAIN	  	 	20	  
			
	 ARTICLE 19
	  	DEFAULT	  	 	21	  
			
	 ARTICLE 20
	  	REMEDIES	  	 	21	  
			
	 ARTICLE 21
	  	TRANSFER OF LANDLORD’S INTEREST	  	 	23	  
			
	 ARTICLE 22
	  	BROKER	  	 	23	  
			
	 ARTICLE 23
	  	PARKING	  	 	23	  
			
	 ARTICLE 24
	  	WAIVER	  	 	24	  
			
	 ARTICLE 25
	  	ESTOPPEL CERTIFICATE	  	 	24	  
			
	 ARTICLE 26
	  	LIABILITY OF LANDLORD	  	 	24	  
			
	 ARTICLE 27
	  	INABILITY TO PERFORM	  	 	25	  
			
	 ARTICLE 28
	  	HAZARDOUS WASTE	  	 	25	  
			
	 ARTICLE 29
	  	SURRENDER OF PREMISES; REMOVAL OF PROPERTY	  	 	26	  
			
	 ARTICLE 30
	  	MISCELLANEOUS	  	 	27	  
	             (a)
	  	SEVERABILITY; ENTIRE AGREEMENT	  	 	27	  
	             (b)
	  	Attorneys’ Fees; Waiver of Jury Trial	  	 	27	  
	             (c)
	  	Time of Essence	  	 	27	  
	             (d)
	  	Headings; Joint and Several	  	 	28	  
	             (e)
	  	Reserved Area	  	 	28	  
	             (f)
	  	NO OPTION	  	 	28	  
	             (g)
	  	Use of Project Name; Improvements	  	 	28	  
	             (h)
	  	Rules and Regulations	  	 	28	  
	             (i)
	  	Quiet Possession	  	 	28	  
	             (j)
	  	Rent	  	 	28	  
	             (k)
	  	Successors and Assigns	  	 	28	  
	             (l)
	  	Notices	  	 	28	  
	             (m)
	  	Persistent Delinquencies	  	 	29	  
	             (n)
	  	Right of Landlord to Perform	  	 	29	  
	             (o)
	  	Access, Changes in Project, Facilities, Name	  	 	29	  
	             (p)
	  	Signing Authority	  	 	29	  
	             (q)
	  	Identification of Tenant	  	 	30	  
	             (r)
	  	Survival of Obligations	  	 	30	  
	             (s)
	  	Confidentiality	  	 	30	  
	             (t)
	  	Governing Law	  	 	30	  
	             (u)
	  	Office of Foreign Assets Control	  	 	31	  
	             (v)
	  	Financial Statements	  	 	31	  
	             (w)
	  	Exhibits	  	 	31	  
	             (x)
	  	Independent Covenants	  	 	31	  
	             (y)
	  	Counterparts	  	 	31	  
	             (z)
	  	Non-Discrimination	  	 	31	  
	             (aa)
	  	Roof Equipment	  	 	31	  
			
	 ARTICLE 31
	  	SIGNAGE/DIRECTORY	  	 	33	  
			
	 ARTICLE 32
	  	CONTINGENCY	  	 	34	  
			
	 ARTICLE 33
	  	OPTION TO EXTEND	  	 	34	  
	             (a)
	  	Option Right	  	 	34	  
	             (b)
	  	Option Rent	  	 	34	  
	             (c)
	  	Exercise of Option	  	 	34	  

  
 (ii)

					
	 	  	 	  	Page
	 EXHIBIT “A”
	  	Premises	  	
	 EXHIBIT “B”
	  	Rules and Regulations	  	
	 EXHIBIT “C”
	  	Notice of Term Dates and Tenant’s Proportionate Share	  	
	 EXHIBIT “D”
	  	Tenant Work Letter	  	
	 EXHIBIT “E”
	  	Letter of Credit	  	

  
 (iii)

 INDEX 

 

					
	 	  	Page(s)	 
	 ADA
	  	 	4	  
	 Additional Rent
	  	 	3	  
	 Affiliate
	  	 	18	  
	 Affiliated Assignee
	  	 	18	  
	 Alterations
	  	 	11	  
	 Approved Working Drawings
	  	 	Exhibit D	  
	 Architect
	  	 	Exhibit D	  
	 Banking Day
	  	 	1	  
	 Base Year
	  	 	1	  
	 Base, Shell and Core
	  	 	Exhibit D	  
	 Basic Rental
	  	 	1	  
	 Beneficiary
	  	 	1	  
	 Brokers
	  	 	2	  
	 Building-Top Signage
	  	 	33	  
	 Cash Security Deposit
	  	 	1	  
	 Code
	  	 	Exhibit D	  
	 Commencement Date
	  	 	1	  
	 Communication Equipment
	  	 	32	  
	 Construction Drawings
	  	 	Exhibit D	  
	 Contingency
	  	 	34	  
	 Contractor
	  	 	Exhibit D	  
	 Control
	  	 	18	  
	 Cost Proposal
	  	 	Exhibit D	  
	 Cost Proposal Delivery Date
	  	 	Exhibit D	  
	 Damage Repair Estimate
	  	 	19	  
	 Direct Costs
	  	 	3	  
	 Dispute Notice
	  	 	6	  
	 Engineers
	  	 	Exhibit D	  
	 Estimate
	  	 	6	  
	 Estimate Statement
	  	 	6	  
	 Estimated Excess
	  	 	6	  
	 Event of Default
	  	 	21	  
	 Excess
	  	 	5	  
	 Expiration Date
	  	 	1	  
	 Final Space Plan
	  	 	Exhibit D	  
	 Final Working Drawings
	  	 	Exhibit D	  
	 Force Majeure
	  	 	25	  
	 Hazardous Material
	  	 	26	  
	 Improvement Allowance
	  	 	Exhibit D	  
	 Improvement Allowance Items
	  	 	Exhibit D	  
	 Improvements
	  	 	Exhibit D	  
	 Initial Installment of Basic Rental
	  	 	2	  
	 Interest Notice
	  	 	34	  
	 ISP98
	  	 	2	  
	 Landlord
	  	 	1	  
	 Landlord Coordination Fee
	  	 	Exhibit D	  
	 Landlord Parties
	  	 	15	  
	 Laws
	  	 	26	  
	 Lease
	  	 	1	  
	 Lease Year
	  	 	2	  
	 LEED
	  	 	10	  
	 Letter of Credit
	  	 	1, 8	  
	 Letter of Credit Return Date
	  	 	8	  
	 Market Rent
	  	 	34	  
	 Monument Signage
	  	 	33	  
	 Operating Costs
	  	 	3	  
	 Option
	  	 	34	  
	 Option Rent
	  	 	34	  
	 Option Rent Notice
	  	 	34	  

  
 (iv)

					
	  	  	Page(s)	 
	 Option Term
	  	 	34	  
	 Original Tenant
	  	 	34	  
	 Over-Allowance Amount
	  	 	Exhibit D	  
	 Parking Passes
	  	 	2	  
	 Partnership Tenant
	  	 	30	  
	 Permits
	  	 	Exhibit D	  
	 Permitted Use
	  	 	2	  
	 Premises
	  	 	1	  
	 Project
	  	 	1	  
	 Real Property
	  	 	3	  
	 Review Notice
	  	 	6	  
	 Review Period
	  	 	6	  
	 Roof Equipment
	  	 	32	  
	 Roof Equipment Notice
	  	 	32	  
	 Rules and Regulations
	  	 	28	  
	 Security Deposit Laws
	  	 	9	  
	 Signage Specifications
	  	 	33	  
	 SNDA
	  	 	20	  
	 Specifications
	  	 	Exhibit D	  
	 Square Footage
	  	 	1	  
	 Standard Improvement Package
	  	 	Exhibit D	  
	 Stated Amount
	  	 	8	  
	 Statement
	  	 	6	  
	 Substantial Completion
	  	 	Exhibit D	  
	 Supplemental Units
	  	 	12	  
	 Tax Costs
	  	 	3	  
	 Tenant
	  	 	1	  
	 Tenant Delays
	  	 	Exhibit D	  
	 Tenant Improvements
	  	 	11	  
	 Tenant’s Acceptance
	  	 	34	  
	 Tenant’s Proportionate Share
	  	 	1	  
	 Tenant’s Signage
	  	 	33	  
	 Term
	  	 	1	  
	 Time Deadlines
	  	 	Exhibit D	  
	 Transfer
	  	 	18	  
	 Transfer Premium
	  	 	18	  
	 Transferee
	  	 	18	  

  
 (v)

 STANDARD OFFICE LEASE 

This Standard Office Lease (“Lease”) is made and entered into as of the 7th day of May, 2013, by and between ARDEN REALTY LIMITED PARTNERSHIP, a
Maryland limited partnership (“Landlord”), and VITAL THERAPIES, INC., a Delaware corporation (“Tenant”). 
 Landlord hereby leases to Tenant and Tenant hereby leases from Landlord the premises described as Suites No. 150 and 200, as designated on the plans attached hereto and incorporated herein as
Exhibit “A” (together, the “Premises”), of the project (“Project”) now known as Carmel Point whose address is 15010 Avenue of Science, San Diego, California, for the Term and upon the terms and
conditions hereinafter set forth, and Landlord and Tenant hereby agree as follows: 
 ARTICLE 1 

BASIC LEASE PROVISIONS 
  

					
	A.	 	Term:	  	Approximately forty-eight (48) months.
			
		 	Commencement Date:	  	The earlier of (i) the date Tenant first commences to conduct business in the Premises, or (ii) the date of Substantial Completion of Improvements in the
Premises. The Commencement Date is anticipated to be on or about August 1, 2013.
			
		 	Expiration Date:	  	The date immediately preceding the forty-eighth (48th) monthly anniversary of the Commencement Date; provided, however, that if the Commencement Date is a date other
than the first (1st) day of a month, the Expiration
Date shall be the last day of the month which is forty-eight (48) months after the month in which the Commencement Date falls, unless extended or earlier terminated pursuant to this Lease.
			
	B.	 	Square Footage:	  	19,118 rentable square feet.
		 		  	

 C. Basic Rental: 
  

													
	 Months
	  	Annual
Basic Rental	 	  	Monthly
Basic Rental*	 	 	Monthly Basic Rental
Per 
Rentable Square Foot	 
	   1 – 12
	  	$	447,361.20	  	  	$	37,280.10	** 	 	$	1.95	  
	 13 – 24
	  	$	461,126.16	  	  	$	38,427.18	  	 	$	2.01	  
	 25 – 36
	  	$	474,891.12	  	  	$	39,574.26	  	 	$	2.07	  
	 37 – 48
	  	$	488,656.08	  	  	$	40,721.34	  	 	$	2.13	  

  

	*	In addition, Tenant shall pay for electricity separately as provided in Section 11(a) below. 

	**	Plus any partial month at the beginning of the Term. 

  

					
	D.	 	 Base Year:
	  	2014
			
	E.	 	 Tenant’s Proportionate Share:
	  	16.18%
			
	F.	 	 Cash Security Deposit:
	  	A cash security deposit of $197,871.30 shall be due and payable by Tenant to Landlord upon Tenant’s execution of this Lease. Such Cash Security Deposit shall be
subject to reduction as provided in Section 4(a) below.
			
	G.	 	 Letter of Credit:
	  	A Letter of Credit in the amount of $150,000.00 shall be delivered by Tenant to Landlord upon Tenant’s execution of this Lease as further provided in
Section 4(b) below. Such Letter of Credit shall be 

					
		 		  	subject to reduction as provided in Section 4(b) below.
			
	H.	 	Permitted Use:	  	General office use consistent with the character of the Project as a first-class office project.
			
	I.	 	Brokers:	  	Jones Lang LaSalle (for Landlord and for Tenant).
			
	J.	 	Parking Passes:	  	Tenant shall be entitled to use four (4) unreserved parking passes for each 1,000 rentable square feet contained in the Premises, which equals seventy-six (76) passes, upon the
terms and conditions provided in Article 23 hereof. Notwithstanding any other provision of this Lease or the Rules and Regulations, there will be no rent or other fee payable from Tenant to Landlord for such parking passes.
			
	K.	 	Initial Installment of Basic Rental:	  	The first full month’s Basic Rental of $37,280.10 shall be due and payable by Tenant to Landlord upon Tenant’s execution of this Lease.

 ARTICLE 2 
 TERM/PREMISES 
 The Term of this Lease shall
commence on the Commencement Date as set forth in Article 1.A. of the Basic Lease Provisions and shall end on the Expiration Date set forth in Article 1.A. of the Basic Lease Provisions. For purposes of this Lease, the term “Lease
Year” shall mean each consecutive twelve (12) month period during the Term, with the first (1st) Lease Year commencing on the Commencement Date; however, (a) if the Commencement Date falls on a day other than the first
(1st) day of a calendar month, the first (1st) Lease Year shall end on the last day of the eleventh
(11th) month after the Commencement Date and the
second (2nd) and each succeeding Lease Year shall
commence on the first (1st) day of the next calendar
month, and (b) the last Lease Year shall end on the Expiration Date. If Landlord does not deliver possession of the Premises to Tenant on or before the anticipated Commencement Date (as set forth in Article 1.A, above), Landlord shall not
be subject to any liability for its failure to do so, and such failure shall not affect the validity of this Lease nor the obligations of Tenant hereunder. Landlord and Tenant hereby stipulate that the Premises contains the number of square feet
specified in Article 1.B. of the Basic Lease Provisions. After the Commencement Date, Landlord may deliver to Tenant a Commencement Letter in a form substantially similar to that attached hereto as Exhibit “C”, which Tenant shall
execute and return to Landlord within five (5) days of receipt thereof. Failure of Tenant to timely execute and deliver the Commencement Letter shall constitute acknowledgment by Tenant that the statements included in such notice are true and
correct, without exception. 
 ARTICLE 3 
 RENTAL 
 (a) Basic Rental. Tenant agrees
to pay to Landlord during the Term hereof, at Landlord’s office or to such other person or at such other place as directed from time to time by written notice to Tenant from Landlord, the monthly and annual sums as set forth in
Article 1.C. of the Basic Lease Provisions, payable in advance on the first (1st) day of each calendar month, without demand, setoff or deduction, and in the event this Lease commences or the date of expiration of this Lease occurs other than on the first (1st) day or last day of a calendar month, the rent for such month
shall be prorated. Notwithstanding the foregoing, the first full month’s Basic Rental shall be paid to Landlord in accordance with Article 1.K. of the Basic Lease Provisions and, if the Commencement Date is not the first day of a month,
Basic Rental for the partial month commencing as of the Commencement Date shall be prorated based upon the actual number of days in such month and shall be due and payable upon the Commencement Date. 

(b) Increase in Direct Costs. The term “Base Year” means the calendar year set forth in Article 1.D. of the
Basic Lease Provisions. If, in any calendar year during the Term of this Lease commencing with the calendar year 2015, the “Direct Costs” (as hereinafter defined) paid or incurred by Landlord shall be higher than the Direct Costs for the
Base Year, Tenant shall pay 

  
 -2-

 
an additional sum for each such subsequent calendar year equal to the product of the amount set forth in Article 1.E. of the Basic Lease Provisions multiplied by such increased amount of
“Direct Costs.” In the event either the Premises and/or the Project is expanded or reduced, then Tenant’s Proportionate Share shall be appropriately adjusted, and as to the calendar year in which such change occurs, Tenant’s
Proportionate Share for such calendar year shall be determined on the basis of the number of days during that particular calendar year that such Tenant’s Proportionate Share was in effect. In the event this Lease shall terminate on any date
other than the last day of a calendar year, the additional sum payable hereunder by Tenant during the calendar year in which this Lease terminates shall be prorated on the basis of the relationship which the number of days which have elapsed from
the commencement of said calendar year to and including said date on which this Lease terminates bears to three hundred sixty five (365). Any and all amounts due and payable by Tenant pursuant to this Lease (other than Basic Rental) shall be deemed
“Additional Rent” and Landlord shall be entitled to exercise the same rights and remedies upon default in these payments as Landlord is entitled to exercise with respect to defaults in monthly Basic Rental payments. Any and all
amounts due and payable by Tenant to Landlord shall be in the form of (i) business checks, (ii) wire transfers, (iii) electronic funds transfers, and (iv) automated clearing house payments. Any other forms of payment are not
acceptable to Landlord including, without limitation (1) cash or currency, (2) cashier’s checks and money orders, (3) traveler’s checks, (4) payments from credit unions or other non-bank financial institutions,
(5) multiple payments for one (1) scheduled payment, and (6) third party checks. 
 (c) Definitions. As
used herein the term “Direct Costs” shall mean the sum of the following: 
 (i) “Tax Costs”,
which shall mean any and all real estate taxes and other similar charges on real property or improvements, assessments, water and sewer charges, and all other charges assessed, reassessed or levied upon the Project and appurtenances thereto and the
parking or other facilities thereof, or the real property thereunder (collectively the “Real Property”) or attributable thereto or on the rents, issues, profits or income received or derived therefrom which are assessed, reassessed
or levied by the United States, the State of California or any local government authority or agency or any political subdivision thereof, and shall include Landlord’s reasonable legal fees, costs and disbursements incurred in connection with
proceedings for reduction of Tax Costs or any part thereof; provided, however, if at any time after the date of this Lease the methods of taxation now prevailing shall be altered so that in lieu of or as a supplement to or a substitute for the whole
or any part of any Tax Costs, there shall be assessed, reassessed or levied (a) a tax, assessment, reassessment, levy, imposition or charge wholly or partially as a net income, capital or franchise levy or otherwise on the rents, issues,
profits or income derived therefrom, or (b) a tax, assessment, reassessment, levy (including but not limited to any municipal, state or federal levy), imposition or charge measured by or based in whole or in part upon the Real Property and
imposed upon Landlord, then except to the extent such items are payable by Tenant under Article 6 below, such taxes, assessments, reassessments or levies or the part thereof so measured or based, shall be deemed to be included in the term
“Direct Costs.” In addition, when calculating Tax Costs for the Base Year, special assessments shall only be deemed included in Tax Costs for the Base Year to the extent that such special assessments are included in Tax Costs for the
applicable subsequent calendar year during the Term. 
 (ii) “Operating Costs”, which shall mean all costs and
expenses incurred by Landlord in connection with the maintenance, operation, replacement, ownership and repair of the Project, the equipment, the intrabuilding cabling and wiring, adjacent walks, malls and landscaped and common areas and the parking
structure, areas and facilities of the Project. Operating Costs shall include but not be limited to, salaries, wages, medical, surgical and general welfare benefits and pension payments, payroll taxes, fringe benefits, employment taxes,
workers’ compensation, uniforms and dry cleaning thereof for all persons who perform duties connected with the operation, maintenance and repair of the Project, its equipment, the intrabuilding cabling and wiring and the adjacent walks and
landscaped areas, including janitorial, gardening, security, parking, operating engineer, elevator, painting, plumbing, electrical, carpentry, heating, ventilation, air conditioning and window washing; hired services; a reasonable allowance for
depreciation of the cost of acquiring or the rental expense of personal property used in the maintenance, operation and repair of the Project; accountant’s fees incurred in the preparation of rent adjustment statements; legal fees; real estate
tax consulting fees; personal property taxes on property used in the maintenance and operation of the Project; fees, 

  
 -3-

 
costs, expenses or dues payable pursuant to the terms of any covenants, conditions or restrictions or owners’ association pertaining to the Project; capital expenditures incurred to effect
economies of operation of, or stability of services to, the Project and capital expenditures required by government regulations, laws, or ordinances including, but not limited to the Americans with Disabilities Act; provided, however, that capital
expenditures included in Operating Costs shall be amortized (with interest at eight percent (8%) per annum) over its useful life; the cost of all charges for gas and water furnished to the Project (including, without limitation, costs incurred
in connection with Landlord’s supplying of “green” or other renewable utilities), and any taxes thereon; the cost of all charges for electricity furnished to the common areas of the Project (including, without limitation, costs
incurred in connection with Landlord’s supplying of “green” or other renewable energy, but excluding any electricity furnished to other tenants of the Project), and any taxes thereon; the cost of all charges for fire and extended
coverage, liability and all other insurance in connection with the Project carried by Landlord; the cost of all building and cleaning supplies and materials; the cost of all charges for cleaning, maintenance and service contracts and other services
with independent contractors and administration fees; a property management fee (which fee may be imputed if Landlord has internalized management or otherwise acts as its own property manager) and license, permit and inspection fees relating to the
Project. In the event, during any calendar year (including the Base Year), the Project is less than ninety-five percent (95%) occupied at all times, Operating Costs shall be adjusted to reflect the Operating Costs of the Project as though
ninety-five percent (95%) were occupied at all times, and the increase or decrease in the sums owed hereunder shall be based upon such Operating Costs as so adjusted. Notwithstanding anything to the contrary set forth in this Article 3,
when calculating Operating Costs for the Base Year, unless Operating Costs for the applicable subsequent calendar year include the applicable following items, Operating Costs shall exclude (a) increases due to extraordinary circumstances
including, but not limited to, labor-related boycotts and strikes, utility rate hikes, utility conservation surcharges, or other surcharges, insurance premiums resulting from terrorism coverage, catastrophic events and/or the management of
environmental risks, and (b) amortization of any capital items including, but not limited to, capital improvements, capital repairs and capital replacements (including such amortized costs where the actual improvement, repair or replacement was
made in prior years). 
 Notwithstanding anything above to the contrary, Operating Costs shall not include (1) the cost of
providing electricity to any other tenants of the Project or the cost of providing any other service directly to and paid directly by any tenant (outside of such tenant’s Direct Cost payments) such as where a tenant directly contracts for
utilities with the local utility company, provided that in each such case, Landlord shall have the right to “gross up” such item (other than electricity) as if such space was vacant; (2) the cost of any items for which Landlord is
reimbursed by insurance proceeds, condemnation awards, a tenant of the Project (outside of such tenant’s Direct Cost payments), or otherwise to the extent so reimbursed; (3) any real estate brokerage commissions or other costs incurred in
procuring tenants, or any fee in lieu of commission; (4) amortization of principal and interest on mortgages or ground lease payments (if any); (5) costs of items considered capital repairs, replacements, improvements and equipment under
generally accepted accounting principles consistently applied except as expressly included in Operating Costs pursuant to the definition above; (6) costs incurred by Landlord due to the violation by Landlord or any tenant of the terms and
conditions of any lease of space in the Project or any law, code, regulation, ordinance or the like; (7) any compensation paid to clerks, attendants or other persons in commercial concessions operated by Landlord (other than in the parking
facility for the Project); (8) costs incurred in connection with upgrading the Project to comply with disability, life, seismic, fire and safety codes, ordinances, statutes, or other laws in effect prior to the Commencement Date, including,
without limitation, the then applicable requirements of the Americans with Disabilities Act (“ADA”), including penalties or damages incurred due to such non-compliance; (9) bad debt expenses and interest, principal, points and
fees on debts (except in connection with the financing of items which may be included in Operating Costs); (10) marketing costs, including those costs described in (3) above, attorneys’ fees in connection with the negotiation and
preparation of letters, deal memos, letters of intent, leases, subleases and/or assignments, space planning costs, and other costs and expenses incurred in connection with lease, sublease and/or assignment negotiations and transactions with present
or prospective tenants or other occupants of the Project, including attorneys’ fees and other costs and expenditures incurred in connection with disputes with present or prospective tenants or other occupants of the Project; (11) costs,
including permit, license and inspection costs, incurred with respect to the installation of other tenants’ or occupants’ improvements made for tenants or other occupants in the Project or incurred in renovating or otherwise improving,
decorating, 

  
 -4-

 
painting or redecorating vacant space for tenants or other occupants in the Project; (12) any costs expressly excluded from Operating Costs elsewhere in this Lease; (13) costs of any
items (including, but not limited to, costs incurred by Landlord for the repair of damage to the Project) to the extent Landlord receives reimbursement from insurance proceeds or from a third party (except that any deductible amount under any
insurance policy shall be included within Operating Costs); (14) rentals and other related expenses for leasing an HVAC system, elevators, or other items (except when needed in connection with normal repairs and maintenance of the Project)
which if purchased, rather than rented, would constitute a capital improvement not included in Operating Costs pursuant to this Lease; (15) depreciation, amortization and interest payments, except as specifically included in Operating Costs
pursuant to the terms of this Lease and except on materials, tools, supplies and vendor-type equipment purchased by Landlord to enable Landlord to supply services Landlord might otherwise contract for with a third party, where such depreciation,
amortization and interest payments would otherwise have been included in the charge for such third party’s services, all as determined in accordance with generally accepted accounting principles, consistently applied, and when depreciation or
amortization is permitted or required, the item shall be amortized over its reasonably anticipated useful life; (16) expenses in connection with services or other benefits which are not offered to Tenant or for which Tenant is charged for
directly but which are provided to another tenant or occupant of the Project, without charge; (17) costs incurred in connection with the operation of retail stores selling merchandise and restaurants in the Project to the extent such costs are
in excess of the costs Landlord reasonably estimates would have been incurred had such space been used for general office use; (18) costs (including in connection therewith all attorneys’ fees and costs of settlement, judgments and/or
payments in lieu thereof) arising from claims, disputes or potential disputes in connection with potential or actual claims litigation or arbitrations pertaining to Landlord and/or the Project, other than such claims or disputes respecting any
services or equipment used in the operation of the Project by Landlord; (19) costs associated with the operation of the business of the partnership which constitutes Landlord as the same are distinguished from the costs of operation of the
Project; (20) costs incurred in connection with the original construction of the Project; (21) costs of correcting defects in or inadequacy of the initial design or construction of the Project; and (22) costs incurred to
(i) comply with laws relating to the removal of any “Hazardous Material,” as that term is defined in Article 28 of this Lease, which was in existence on the Project prior to the Commencement Date, and was of such a nature that a
federal, state or municipal governmental authority, if it had then had knowledge of the presence of such Hazardous Material, in the state, and under the conditions that it then existed on the Project, would have then required the removal of such
Hazardous Material or other remedial or containment action with respect thereto, and (ii) remove, remedy, contain, or treat any Hazardous Material, which Hazardous Material is brought onto the Project after the date hereof by Landlord or any
other tenant of the Project and is of such a nature, at that time, that a federal, state or municipal governmental authority, if it had then had knowledge of the presence of such Hazardous Material, in the state, and under the conditions, that it
then exists on the Project, would have then required the removal of such Hazardous Material or other remedial or containment action with respect thereto. 
 In addition, notwithstanding anything to the contrary contained herein, the aggregate Controllable Operating Costs, as that term is defined below, shall not increase more than six percent (6%) in any
calendar year over the maximum amount of Controllable Operating Costs chargeable for the immediately preceding calendar year, with no limit on the Controllable Operating Costs during the Base Year (i.e., the actual Controllable Operating Costs for
the Base Year shall be the maximum amount for the Base Year for purposes of this provision). “Controllable Operating Costs” shall mean wages, salaries and other compensation and benefits paid to Landlord’s non-union employees
engaged in the operation, management, maintenance or security of the Project, any management fee paid to any affiliate of Landlord and any rental paid for any management office of the Project. 

(d) Determination of Payment. 
 (i) If for any calendar year ending or commencing within the Term, Tenant’s Proportionate Share of Direct Costs for such calendar year exceeds Tenant’s Proportionate Share of Direct Costs for
the Base Year, then Tenant shall pay to Landlord, in the manner set forth in Sections 3(d)(ii) and (iii), below, and as Additional Rent, an amount equal to the excess (the “Excess”). 

  
 -5-

 (ii) Landlord shall give Tenant a yearly expense estimate statement
(the “Estimate Statement”) which shall set forth Landlord’s reasonable estimate (the “Estimate”) of what the total amount of Direct Costs for the then-current calendar year shall be and the estimated Excess
(the “Estimated Excess”) as calculated by comparing Tenant’s Proportionate Share of Direct Costs for such calendar year, which shall be based upon the Estimate, to Tenant’s Proportionate Share of Direct Costs for the Base
Year. The failure of Landlord to timely furnish the Estimate Statement for any calendar year shall not preclude Landlord from subsequently enforcing its rights to collect any Estimated Excess under this Article 3, once such Estimated Excess has
been determined by Landlord. If pursuant to the Estimate Statement an Estimated Excess is calculated for the then-current calendar year, Tenant shall pay, with its next installment of Monthly Basic Rental due, a fraction of the Estimated Excess for
the then-current calendar year (reduced by any amounts paid pursuant to the last sentence of this Section 3(d)(ii)). Such fraction shall have as its numerator the number of months which have elapsed in such current calendar year to the month of
such payment, both months inclusive, and shall have twelve (12) as its denominator. Until a new Estimate Statement is furnished, Tenant shall pay monthly, with the Monthly Basic Rental installments, an amount equal to one-twelfth (1/12th) of the total Estimated Excess set forth in the previous
Estimate Statement delivered by Landlord to Tenant. 
 (iii) In addition, Landlord shall endeavor to give to Tenant as soon as
reasonably practicable following the end of each calendar year, a statement (the “Statement”) which shall state the Direct Costs incurred or accrued for such preceding calendar year, and which shall indicate the amount, if any, of
the Excess. Upon receipt of the Statement for each calendar year during the Term, if amounts paid by Tenant as Estimated Excess are less than the actual Excess as specified on the Statement, Tenant shall pay, with its next installment of monthly
Basic Rental due, the full amount of the Excess for such calendar year, less the amounts, if any, paid during such calendar year as Estimated Excess. If, however, the Statement indicates that amounts paid by Tenant as Estimated Excess are greater
than the actual Excess as specified on the Statement, such overpayment shall be credited against Tenant’s next installments of Estimated Excess. The failure of Landlord to timely furnish the Statement for any calendar year shall not prejudice
Landlord from enforcing its rights under this Article 3, once such Statement has been delivered. Even though the Term has expired and Tenant has vacated the Premises, when the final determination is made of Tenant’s Proportionate Share of the
Direct Costs for the calendar year in which this Lease terminates, if an Excess is present, Tenant shall immediately pay to Landlord an amount as calculated pursuant to the provisions of this Section 3(d). The provisions of this
Section 3(d)(iii) shall survive the expiration or earlier termination of the Term. 
 (iv) If the Project is a part of a
multi-building development, those Direct Costs attributable to such development as a whole (and not attributable solely to any individual building therein) shall be allocated by Landlord to the Project and to the other buildings within such
development on an equitable basis. 
 (e) Audit Right. Within one hundred twenty (120) days after receipt of a
Statement by Tenant (“Review Period”), if Tenant disputes the amount set forth in the Statement, Tenant’s employees or an independent certified public accountant (which accountant is a member of a nationally or regionally
recognized accounting firm and is not retained on a contingency fee basis), designated by Tenant, may, after reasonable notice to Landlord (“Review Notice”) and at reasonable times, inspect Landlord’s records at Landlord’s
offices, provided that Tenant is not then in default after expiration of all applicable cure periods and provided further that Tenant and such accountant or representative shall, and each of them shall use their commercially reasonable efforts to
cause their respective agents and employees to, maintain all information contained in Landlord’s records in strict confidence. Notwithstanding the foregoing, Tenant shall only have the right to review Landlord’s records one (1) time
during any twelve (12) month period. If after such inspection, but within thirty (30) days after the Review Period, Tenant notifies Landlord in writing (“Dispute Notice”) that Tenant still disputes such amounts, a
certification as to the proper amount shall be made in accordance with Landlord’s standard accounting practices, at Tenant’s expense, by an independent certified public accountant selected by Landlord and who is a member of a nationally or
regionally recognized accounting firm. Tenant’s failure to deliver the Review Notice within the Review Period or to deliver the Dispute Notice within thirty (30) days after the Review Period shall be deemed to constitute Tenant’s
approval of such Statement and Tenant, thereafter, waives the right or ability to dispute the amounts set forth in such Statement. If Tenant timely delivers the Review Notice and the Dispute Notice, Landlord shall cooperate in good faith with Tenant
and the accountant to show Tenant and the accountant the 

  
 -6-

 
information upon which the certification is to be based. However, if such certification by the accountant proves that the Direct Costs set forth in the Statement were overstated by more than ten
percent (10%), then the cost of the accountant and the cost of such certification shall be paid for by Landlord. Promptly following the parties receipt of such certification, the parties shall make such appropriate payments or reimbursements, as the
case may be, to each other, as are determined to be owing pursuant to such certification. Tenant agrees that this section shall be the sole method to be used by Tenant to dispute the amount of any Direct Costs payable by Tenant pursuant to the terms
of this Lease, and Tenant hereby waives any other rights at law or in equity relating thereto. 
 ARTICLE 4

 CASH SECURITY DEPOSIT/LETTER OF CREDIT 

(a) Cash Security Deposit. Tenant has deposited or concurrently herewith is depositing with Landlord the sum
set forth in Article 1.F. of the Basic Lease Provisions as security for the full and faithful performance of every provision of this Lease to be performed by Tenant. If Tenant breaches any provision of this Lease, including but not limited to
the payment of rent, Landlord may use all or any part of this cash security deposit for the payment of any rent or any other sums in default, or to compensate Landlord for any other loss or damage which Landlord may suffer by reason of Tenant’s
default. If any portion of said deposit is so used or applied, Tenant shall, within five (5) days after written demand therefor, deposit funds with Landlord in a form acceptable under Section 3(b) above and in an amount sufficient to
restore the cash security deposit to its full amount. Tenant agrees that Landlord shall not be required to keep the cash security deposit in trust, segregate it or keep it separate from Landlord’s general funds, but Landlord may commingle the
cash security deposit with its general funds and Tenant shall not be entitled to interest on such deposit. At the expiration of the Term, and provided there exists no default by Tenant hereunder, the cash security deposit or any balance thereof
shall be returned to Tenant (or, at Landlord’s option, to Tenant’s “Transferee”, as such term is defined in Article 15 below), provided that subsequent to the expiration of this Lease, Landlord may retain from said cash
security deposit (i) an amount reasonably estimated by Landlord to cover potential Direct Cost reconciliation payments due with respect to the calendar year in which this Lease terminates or expires (such amount so retained shall not, in any
event, exceed ten percent (10%) of estimated Direct Cost payments due from Tenant for such calendar year through the date of expiration or earlier termination of this Lease and any amounts so retained and not applied to such reconciliation
shall be returned to Tenant within thirty (30) days after Landlord’s delivery of the Statement for such calendar year), (ii) any and all amounts reasonably estimated by Landlord to cover the anticipated costs to be incurred by
Landlord to remove any signage provided to Tenant under this Lease, to remove cabling and other items required to be removed by Tenant under Section 29(b) below and to repair any damage caused by such removal (in which case any excess amount so
retained by Landlord shall be returned to Tenant within thirty (30) days after such removal and repair), and (iii) any and all amounts permitted by law or this Section 4(a). Tenant hereby waives the provisions of Section 1950.7
of the California Civil Code and all other provisions of law, now or hereafter in effect, which provide that Landlord may claim from a cash security deposit only those sums reasonably necessary to remedy defaults in the payment of rent, to repair
damage caused by Tenant or to clean the Premises, it being agreed that Landlord may, in addition, claim those sums specified in this Section 4(a) above, and all of Landlord’s damages under this Lease and California law including, but not
limited to, any damages accruing upon termination of this Lease under Section 1951.2 of the California Civil Code and/or those sums reasonably necessary to compensate Landlord for any other loss or damage, foreseeable or unforeseeable, caused
by the acts or omissions of Tenant or any officer, employee, agent, contractor or invitee of Tenant. Notwithstanding anything to the contrary contained in this Section 4(a), in the event that Tenant, at the expiration of the twenty-fourth
(24th), twenty-eighth (28th), thirty-second (32nd) and/or thirty-sixth (36th) full calendar months of the initial Lease Term, is not in
default of any of its obligations under this Lease (or if Tenant is then in default, upon Tenant’s cure of such default), Landlord shall reduce the amount of the cash security deposit by the amount of the monthly Basic Rental due and payable to
Landlord for the next full calendar month(s) of the initial Lease Term, respectively, and Landlord shall apply such amounts against Tenant’s monthly Basic Rental obligation for such next full calendar month(s). 

(b) Letter of Credit. 
 (i) Stated Amount. Within ten (10) days after Tenant’s execution and delivery of this Lease, Tenant shall deliver to Landlord an unconditional, irrevocable and

  
 -7-

 
renewable letter of credit (“Letter of Credit”) in favor of Landlord in the form attached hereto as Exhibit E, issued by a financial institution satisfactory to Landlord, in
the principal amount (“Stated Amount”) specified below, to be held by Landlord in accordance with the terms, provisions and conditions of this Lease. Tenant shall pay all expenses, points and/or fees incurred by Tenant in obtaining
the Letter of Credit. If the Letter of Credit delivered by Tenant is inconsistent with the form attached hereto as Exhibit E (including, without limitation, the wrong name or address for the Beneficiary), Landlord may so notify Tenant in
writing, in which case Tenant shall cause the Letter of Credit to be corrected within five (5) business days after such notice. Landlord shall be entitled to draw upon the Letter of Credit if the credit rating or financial condition of the
issuer of the Letter of Credit is no longer reasonably acceptable to Landlord. Following any such draw by Landlord on the Letter of Credit solely because of the deterioration of the creditworthiness of the issuer of the Letter of Credit, Landlord
will disburse such Letter of Credit proceeds to Tenant provided (A) Tenant delivers to Landlord a replacement Letter of Credit from a financial institution satisfactory to Landlord in the form attached hereto as Exhibit “E”
within sixty (60) days after Landlord’s draw thereon, (B) there exists no event of default with respect to any provision of this Lease, and (C) Tenant pays all of Landlord’s fees and expenses incurred in connection with such
disbursement; provided, however, if any of the three (3) foregoing conditions are not satisfied, the proceeds received from such draw shall constitute Landlord’s property (and not Tenant’s property or the property of the bankruptcy
estate of Tenant) and Landlord may then use, apply or retain all or any part of the proceeds for the purposes set forth in clauses (1) through (5) of the next paragraph. The Stated Amount shall initially be One Hundred Fifty Thousand
Dollars ($150,000.00); provided, however, that, except as hereinafter provided, upon the last day of the thirty-sixth
(36th) month of the initial Term (the “Letter
of Credit Return Date”), Landlord shall return the Letter of Credit to Tenant and this Section 4(b) shall be of no further force and effect. However, if (i) a default by Tenant occurs under this Lease, or (ii) circumstances
exist that would, with notice or lapse of time, or both, constitute a default by Tenant, and in the case of (i) or (ii) Tenant has failed to cure such default within the time period permitted by Article 19 or such lesser time as may
remain before the Letter of Credit Return Date as provided above, the Letter of Credit shall not be returned to Tenant and this Section 4(b) shall continue to be in force and effect, unless and until such default shall have been fully cured
pursuant to the terms of this Lease, at which time Landlord shall return to Tenant the Letter of Credit and this Section 4(b) shall be of no further force and effect as hereinabove described. 

(ii) Demands on Letter of Credit. The Letter of Credit shall state that an authorized officer or other representative of Landlord
may make demand on Landlord’s behalf for the Stated Amount of the Letter of Credit, or any portion thereof, and that the issuing bank must immediately honor such demand, without qualification or satisfaction of any conditions, except the proper
identification of the party making such demand. In addition, the Letter of Credit shall indicate that it is transferable in its entirety by Landlord as beneficiary and that upon receiving written notice of transfer, and upon presentation to the
issuing bank of the original Letter of Credit, the issuer or confirming bank will reissue the Letter of Credit naming such transferee as the beneficiary. Tenant shall be responsible for the payment to the issuing bank of any transfer costs imposed
by the issuing bank in connection with any such transfer. If (A) the term of the Letter of Credit held by Landlord will expire prior to the last day of the Lease Term and the Letter of Credit is not extended, or a new Letter of Credit for an
extended period of time is not substituted, in either case at least sixty (60) days prior to the expiration of the Letter of Credit, or (B) Tenant commits a default with respect to any provision of this Lease, which is not cured within any
applicable cure period, including the filing of a voluntary petition under Title 11 of the United States Code (i.e., the Bankruptcy Code), or otherwise becomes a debtor in any case or proceeding under the Bankruptcy Code, as now existing or
hereinafter amended, or any similar law or statute, Landlord may (but shall not be required to) draw upon all or any portion of the Stated Amount of the Letter of Credit, and the proceeds received from such draw shall constitute Landlord’s
property (and not Tenant’s property or the property of the bankruptcy estate of Tenant) and Landlord may then use, apply or retain all or any part of the proceeds (1) for the payment of any sum which is in default, (2) to reimburse
Landlord for costs incurred by Landlord in connection with this Lease (including, without limitation, any costs incurred by Landlord to improve the Premises, and any brokerage commissions and attorneys’ fees), (3) for the payment of any
other amount which Landlord may spend or become obligated to spend by reason of Tenant’s default, (4) to compensate Landlord for any loss or damage which Landlord may suffer by reason of Tenant’s default or (5) as prepaid rent to
be applied against Tenant’s Basic Rental obligations for the last month of the Term and the immediately preceding month(s) 

  
 -8-

 
of the Term until the remaining proceeds are exhausted. If any portion of the Letter of Credit proceeds are so used or applied, Tenant shall, within ten (10) days after demand therefor, post
an additional Letter of Credit in an amount to cause the aggregate amount of the unused proceeds and such new Letter of Credit to equal the Stated Amount required in Section 4(b)(i) above. Landlord shall not be required to keep any proceeds
from the Letter of Credit separate from its general funds. Should Landlord sell its interest in the Premises during the Lease Term and if Landlord deposits with the purchaser thereof the Letter of Credit or any proceeds of the Letter of Credit,
thereupon Landlord shall be discharged from any further liability with respect to the Letter of Credit and said proceeds and Tenant shall look solely to such transferee for the return of the Letter of Credit or any proceeds therefrom. 

(iii) Reservation of Rights. The use, application or retention of the Letter of Credit, the proceeds or any portion thereof, shall
not prevent Landlord from exercising any other rights or remedies provided under this Lease, it being intended that Landlord shall not be required to proceed against the Letter of Credit, and such use, application or retention of the Letter of
Credit shall not operate as a limitation on any recovery to which Landlord may otherwise be entitled. No trust relationship is created herein between Landlord and Tenant with respect to the Letter of Credit. 

(iv) Waiver of Security Deposit Laws. Landlord and Tenant acknowledge and agree that in no event or circumstance shall the Letter
of Credit, any renewal thereof or substitute therefor or the proceeds thereof be (i) deemed to be or treated as a “security deposit” within the meaning of California Civil Code Section 1950.7, (ii) subject to the terms of
such Section 1950.7, or (iii) intended to serve as a “security deposit” within the meaning of such Section 1950.7. The parties hereto (A) recite that the Letter of Credit is not intended to serve as a security deposit
and such Section 1950.7 and any and all other laws, rules and regulations applicable to security deposits in the commercial context (“Security Deposit Laws”) shall have no applicability or relevancy thereto and (B) waive
any and all rights, duties and obligations either party may now or, in the future, will have relating to or arising from the Security Deposit Laws. Notwithstanding the foregoing, to the extent California Civil Code Section 1950.7 in any way:
(a) is applicable to this Lease or the Letter of Credit (or any proceeds thereof); or (b) controls Landlord’s rights to draw on the Letter of Credit or apply the proceeds of the Letter of Credit to any amounts due under the Lease or
any damages Landlord may suffer following termination of this Lease, then Tenant fully and irrevocably waives the benefits and protections of Section 1950.7 of the California Civil Code, it being agreed that Landlord may recover from the Letter
of Credit (or its proceeds) all of Landlord’s damages under this Lease and California law including, but not limited to, any damages accruing upon the termination of this Lease in accordance with this Lease and Section 1951.2 of the
California Civil Code. 
 ARTICLE 5 
 HOLDING OVER 
 Should Tenant (or any subtenant, assignee or other
party occupying the Premises by, through, under, or with the permission of Tenant), without Landlord’s written consent, hold over after termination of this Lease, Tenant shall, at Landlord’s option, become either a tenant at sufferance or
a month-to-month tenant upon each and all of the terms herein provided as may be applicable to such a tenancy and any such holding over shall not constitute an extension of this Lease. During such holding over, Tenant shall pay in advance, monthly,
Basic Rental at a rate equal to one hundred fifty percent (150%) of the rate in effect for the last month of the Term of this Lease, in addition to, and not in lieu of, all other payments required to be made by Tenant hereunder including but
not limited to Tenant’s Proportionate Share of any increase in Direct Costs. Nothing contained in this Article 5 shall be construed as consent by Landlord to any holding over of the Premises by Tenant, and Landlord expressly reserves the
right to require Tenant to surrender possession of the Premises to Landlord as provided in this Lease upon the expiration or earlier termination of the Term. If Tenant fails to surrender the Premises upon the expiration or termination of this Lease,
Tenant agrees to indemnify, defend and hold Landlord harmless from and against all costs, loss, expense or liability, including without limitation, claims made by any succeeding tenant and real estate brokers claims and attorney’s fees and
costs. 

  
 -9-

 ARTICLE 6 

OTHER TAXES 
 Tenant shall pay, prior to delinquency, all taxes assessed against or levied upon trade fixtures, furnishings, equipment and all other personal property of Tenant located in the Premises. In the event any
or all of Tenant’s trade fixtures, furnishings, equipment and other personal property shall be assessed and taxed with property of Landlord, or if the cost or value of any leasehold improvements in the Premises exceeds the cost or value of a
Project-standard buildout as determined by Landlord and, as a result, real property taxes for the Project are increased, Tenant shall pay to Landlord, within ten (10) days after delivery to Tenant by Landlord of a written statement setting
forth such amount, the amount of such taxes applicable to Tenant’s property or above-standard improvements. Tenant shall assume and pay to Landlord at the time Basic Rental next becomes due (or if assessed after the expiration of the Term, then
within ten (10) days), any excise, sales, use, rent, occupancy, garage, parking, gross receipts or other taxes (other than net income taxes) which may be assessed against or levied upon Landlord on account of the letting of the Premises or the
payment of Basic Rental or any other sums due or payable hereunder, and which Landlord may be required to pay or collect under any law now in effect or hereafter enacted. In addition to Tenant’s obligation pursuant to the immediately preceding
sentence, Tenant shall pay directly to the party or entity entitled thereto all business license fees, gross receipts taxes and similar taxes and impositions which may from time to time be assessed against or levied upon Tenant, as and when the same
become due and before delinquency. Notwithstanding anything to the contrary contained herein, any sums payable by Tenant under this Article 6 shall not be included in the computation of “Tax Costs.” 

ARTICLE 7 
 USE 
 Tenant shall use and occupy the Premises only for the use set
forth in Article 1.H. of the Basic Lease Provisions and shall not use or occupy the Premises or permit the same to be used or occupied for any other purpose without the prior written consent of Landlord, which consent may be given or withheld
in Landlord’s sole and absolute discretion, and Tenant agrees that it will use the Premises in such a manner so as not to interfere with or infringe upon the rights of other tenants or occupants in the Project. Tenant shall, at its sole cost
and expense, promptly comply with all laws, statutes, ordinances, governmental regulations or requirements now in force or which may hereafter be in force relating to or affecting (i) the condition, use or occupancy of the Premises or the
Project (excluding structural changes to the Project not related to Tenant’s particular use of the Premises), and (ii) improvements installed or constructed in the Premises by or for the benefit of Tenant. Tenant shall not permit more than
six (6) people per one thousand (1,000) rentable square feet of the Premises to occupy the Premises at any time. Tenant shall not do or permit to be done anything which would invalidate or increase the cost of any insurance policy covering
the Project and/or the property located therein and Tenant shall comply with all rules, orders, regulations and requirements of any organization which sets out standards, requirements or recommendations commonly referred to by major fire insurance
underwriters, and Tenant shall promptly upon demand reimburse Landlord for any additional premium charges for any such insurance policy assessed or increased by reason of Tenant’s failure to comply with the provisions of this Article 7.
Tenant shall comply with Landlord’s reasonable sustainability practices and shall not permit any use of the Premises which may affect the continued certification of the Project issued pursuant to the United States Green Building Council’s
Leadership in Energy and Environmental Design (“LEED”)rating system (or other applicable certification standard). 
 ARTICLE 8 
 CONDITION OF PREMISES 

Tenant hereby agrees that except as provided in the Tenant Work Letter attached hereto as Exhibit “D” and made a part
hereof, the Premises shall be taken “as is”, “with all faults”, “without any representations or warranties”, and Tenant hereby agrees and warrants that it has investigated and inspected the condition of the Premises and
the suitability of same for Tenant’s purposes, and Tenant does hereby waive and disclaim any objection to, cause of action based upon, or claim that its obligations hereunder should be reduced or limited because of the condition of the Premises
or the Project or the suitability of same for Tenant’s purposes. Tenant acknowledges that neither Landlord nor any agent nor any employee of Landlord has made any representations or warranty with respect to the Premises or the Project or with
respect to the 

  
 -10-

 
suitability of either for the conduct of Tenant’s business and Tenant expressly warrants and represents that Tenant has relied solely on its own investigation and inspection of the Premises
and the Project in its decision to enter into this Lease and let the Premises in the above-described condition. Nothing contained herein is intended to, nor shall, obligate Landlord to implement sustainability practices for the Project or to seek
certification under, or make modifications in order to obtain, a certification from LEED or any other comparable certification. The Premises shall be initially improved as provided in, and subject to, the Tenant Work Letter attached hereto as
Exhibit “D” and made a part hereof. The existing leasehold improvements in the Premises as of the date of this Lease, together with the Improvements (as defined in the Tenant Work Letter) may be collectively referred to herein as the
“Tenant Improvements.” The taking of possession of the Premises by Tenant shall conclusively establish that the Premises and the Project were at such time in satisfactory condition. Tenant hereby waives subsection 1 of
Section 1932 and Sections 1941 and 1942 of the Civil Code of California or any successor provision of law. 

ARTICLE 9 
 REPAIRS AND ALTERATIONS 
 (a) Landlord’s Obligations.
Landlord shall maintain the structural portions of the Project, including the foundation, floor/ceiling slabs, roof, curtain wall, exterior glass, columns, beams, shafts, stairs, stairwells, elevator cabs and common areas, and shall also maintain
and repair the basic mechanical, electrical, life safety, plumbing, sprinkler systems and heating, ventilating and air-conditioning systems (provided, however, that Landlord’s obligation with respect to any such systems shall be to repair and
maintain those portions of the systems located in the core of the Project or in other areas outside of the Premises, but Tenant shall be responsible to repair and maintain any distribution of such systems throughout the Premises). 

(b) Tenant’s Obligations. Except as expressly provided as Landlord’s obligation in this Article 9, Tenant shall
keep the Premises in good condition and repair and in compliance with Landlord’s sustainability practices including, without limitation, compliance with any LEED rating system (or other certification standard) applicable to the Project. All
damage or injury to the Premises or the Project resulting from the act or negligence of Tenant, its employees, agents or visitors, guests, invitees or licensees or by the use of the Premises, shall be promptly repaired by Tenant at its sole cost and
expense, to the satisfaction of Landlord; provided, however, that for damage to the Project as a result of casualty or for any repairs that may impact the mechanical, electrical, plumbing, heating, ventilation or air-conditioning systems of the
Project, Landlord shall have the right (but not the obligation) to select the contractor and oversee all such repairs. Landlord may make any repairs which are not promptly made by Tenant after Tenant’s receipt of written notice and the
reasonable opportunity of Tenant to make said repair within five (5) business days from receipt of said written notice, and charge Tenant for the cost thereof, which cost shall be paid by Tenant within five (5) days from invoice from
Landlord. Tenant shall be responsible for the design and function of all non-standard improvements of the Premises, whether or not installed by Landlord at Tenant’s request. Tenant waives all rights to make repairs at the expense of Landlord,
or to deduct the cost thereof from the rent. 
 (c) Alterations. Tenant shall make no alterations, installations, changes
or additions in or to the Premises or the Project (collectively, “Alterations”) without Landlord’s prior written consent. Without limitation as to other grounds for Landlord withholding its consent to any proposed Alteration,
Landlord may withhold its consent to a proposed Alteration if Landlord determines that such Alteration is not compatible with any existing or planned future certification of the Project under the LEED rating system (or other applicable certification
standard). Any Alterations approved by Landlord must be performed in accordance with the terms hereof, using only contractors or mechanics approved by Landlord in writing and upon the approval by Landlord in writing of fully detailed and dimensioned
plans and specifications pertaining to the Alterations in question, to be prepared and submitted by Tenant at its sole cost and expense. Tenant shall at its sole cost and expense obtain all necessary approvals and permits pertaining to any
Alterations approved by Landlord. Tenant shall cause all Alterations to be performed in a good and workmanlike manner, in conformance with all applicable federal, state, county and municipal laws, rules and regulations, pursuant to a valid building
permit, and in conformance with Landlord’s construction rules and regulations. If Landlord, in approving any Alterations, specifies a commencement date therefor, Tenant shall not commence any work with respect to such Alterations prior to such
date. Tenant hereby agrees to indemnify, defend, and hold Landlord free and harmless from all liens and claims of lien, and all other liability, claims 

  
 -11-

 
and demands arising out of any work done or material supplied to the Premises by or at the request of Tenant in connection with any Alterations. Tenant shall be entitled to install, as an initial
Tenant Improvement or as an Alteration, dedicated heating, ventilation and air conditioning units (“Supplemental Units”) within the Premises at Tenant’s sole cost and expense. The plans and specifications for any Supplemental
Units shall, as indicated in this Article 9 above and the Tenant Work Letter (as applicable), be subject to Landlord’s reasonable approval. If Tenant elects to install Supplemental Units within the Premises, Tenant shall be responsible for the
cost of electricity supplied to such units pursuant to the procedure described in Section 11(a) below. Tenant shall be solely responsible for maintenance and repair of the Supplemental Units and such units shall be considered to be a fixture
within the Premises and shall remain upon the Premises upon the expiration or earlier termination of the Lease Term. 
 (d)
Insurance; Liens. Prior to the commencement of any Alterations, Tenant shall provide Landlord with evidence that Tenant carries “Builder’s All Risk” insurance in an amount approved by Landlord covering the construction of such
Alterations, and such other insurance as Landlord may reasonably require, it being understood that all such Alterations shall be insured by Tenant pursuant to Article 14 of this Lease immediately upon completion thereof. In addition, Landlord
may, in its discretion, require Tenant to obtain a bond or some alternate form of security satisfactory to Landlord in an amount sufficient to ensure the lien free completion of such Alterations. 

(e) Costs and Fees; Removal. If permitted Alterations are made, they shall be made at Tenant’s sole cost and expense and
shall be and become the property of Landlord, except that Landlord may, by written notice to Tenant given at the time of Landlord’s consent to any Improvements or Alterations, require Tenant at Tenant’s expense to remove such Improvements
or other Alterations from the Premises upon expiration or earlier termination of this Lease, and to repair any damage to the Premises and the Project caused by such removal. Notwithstanding any other provision of this Lease, Tenant shall not,
however, be required to remove any of the existing (as of the date of this Lease) Tenant Improvements in the Premises or any Tenant Improvement shown on the Final Space Plan (as such term is defined in the Tenant Work Letter attached hereto as
Exhibit “D” and incorporated herein by this reference). Any and all costs attributable to or related to the applicable building codes of the city in which the Project is located (or any other authority having jurisdiction over the Project)
arising from Tenant’s plans, specifications, improvements, Alterations or otherwise shall be paid by Tenant at its sole cost and expense. With regard to repairs, Alterations or any other work arising from or related to this Article 9,
Landlord shall be entitled to receive an administrative/coordination fee (which fee shall vary depending upon whether or not Tenant orders the work directly from Landlord) sufficient to compensate Landlord for all overhead, general conditions, fees
and other costs and expenses arising from Landlord’s involvement with such work. The construction of initial improvements to the Premises shall be governed by the terms of the Tenant Work Letter and not the terms of this Article 9, except
as expressly provided in the first sentence of this Section 9(e). 
 ARTICLE 10 

LIENS 
 Tenant shall keep the Premises and the Project free from any mechanics’ liens, vendors liens or any other liens arising out of any work performed, materials furnished or obligations incurred by
Tenant, and Tenant agrees to defend, indemnify and hold Landlord harmless from and against any such lien or claim or action thereon, together with costs of suit and reasonable attorneys’ fees and costs incurred by Landlord in connection with
any such claim or action. Before commencing any work of alteration, addition or improvement to the Premises, Tenant shall give Landlord at least ten (10) business days’ written notice of the proposed commencement of such work (to afford
Landlord an opportunity to post appropriate notices of non-responsibility). In the event that there shall be recorded against the Premises or the Project or the property of which the Premises is a part any claim or lien arising out of any such work
performed, materials furnished or obligations incurred by Tenant and such claim or lien shall not be removed or discharged within ten (10) days of filing, Landlord shall have the right but not the obligation to pay and discharge said lien
without regard to whether such lien shall be lawful or correct (in which case Tenant shall reimburse Landlord for any such payment made by Landlord within ten (10) days following written demand), or to require that Tenant promptly deposit with
Landlord in cash, lawful money of the United States, one hundred fifty percent (150%) of the amount of such claim, which sum may be retained by Landlord until such claim shall have been removed of record or until judgment shall have been
rendered on such claim and such judgment 

  
 -12-

 
shall have become final, at which time Landlord shall have the right to apply such deposit in discharge of the judgment on said claim and any costs, including attorneys’ fees and costs
incurred by Landlord, and shall remit the balance thereof to Tenant. 
 ARTICLE 11 

PROJECT SERVICES 
 (a) Basic Services. Landlord agrees to furnish to the Premises, at a cost to be included in Operating Costs, from 7:00 a.m. to 6:00 p.m. Mondays through Fridays and 9:00 a.m. to
1:00 p.m. on Saturdays, excepting local and national holidays, air conditioning and heat all in such reasonable quantities as in the judgment of Landlord is reasonably necessary for the comfortable occupancy of the Premises. In addition,
Landlord shall provide electric current for normal lighting and normal office machines, elevator service and water on the same floor as the Premises for lavatory and drinking purposes in such reasonable quantities as in the judgment of Landlord is
reasonably necessary for general office use and in compliance with applicable codes. To the extent reasonably determined by Landlord to be practicable, all such electricity (including, without limitation, electricity in order to power the heating,
ventilation and air conditioning system serving the Premises), shall be separately metered or submetered at Tenant’s expense and Tenant shall make payment directly to the entity providing such electricity to the Premises if such separate meters
are installed. If, however, separate meters are not installed and the Premises are submetered or are jointly metered, then Landlord shall determine and Tenant shall pay the amount reasonably determined by Landlord to be Tenant’s equitable share
of the monthly charge for such electricity, as Additional Rent. Tenant shall cooperate with Landlord’s efforts to cause the utilities for the Project to comply with Landlord’s sustainability practices and any LEED rating (or other
applicable certification standard) applicable to the Project. Such efforts may include, without limitation, the use of energy efficient bulbs in task lighting, energy efficient lighting controls and measures to avoid over-lighting interior spaces.
Janitorial and maintenance services shall be furnished five (5) days per week, excepting local and national holidays. Tenant shall comply with all rules and regulations which Landlord may establish for the proper functioning and protection of
the common area air conditioning, heating, elevator, electrical, intrabuilding cabling and wiring and plumbing systems. Landlord shall not be liable for, and there shall be no rent abatement as a result of, any stoppage, reduction or interruption of
any such services caused by governmental rules, regulations or ordinances, riot, strike, labor disputes, breakdowns, accidents, necessary repairs or other cause. Except as specifically provided in this Article 11, Tenant agrees to pay for all
utilities and other services utilized by Tenant and any additional building services furnished to Tenant which are not uniformly furnished to all tenants of the Project, at the rate generally charged by Landlord to tenants of the Project for such
utilities or services. 
 (b) Excess Usage. Tenant will not, without the prior written consent of Landlord, use any
apparatus or device in the Premises which will in any way increase the amount of electricity or water usually furnished or supplied for use of the Premises as general office space; nor connect any apparatus, machine or device with water pipes or
electric current (except through existing electrical outlets in the Premises), for the purpose of using electric current or water. Tenant shall promptly respond to all reasonable informational requests made by Landlord from time to time regarding
Landlord’s reporting requirements under the LEED rating system (or other applicable certification standard) including, without limitation, informational requests regarding Tenant’s utility usage. 

(c) Additional Electrical Service. If Tenant shall require electric current in excess of that which Landlord is obligated to
furnish under Section 11(a) above, Tenant shall first obtain the written consent of Landlord, which Landlord may refuse in its sole and absolute discretion. 
 (d) HVAC Balance. If any lights, machines or equipment (including but not limited to computers and computer systems and appurtenances) are used by Tenant in the Premises which materially affect the
temperature otherwise maintained by the air conditioning system, or generate substantially more heat in the Premises than would be generated by the building standard lights and usual office equipment, Landlord shall have the right to install any
machinery and equipment which Landlord reasonably deems necessary to restore temperature balance, including but not limited to modifications to the standard air conditioning equipment, and the cost thereof, including the cost of installation and any
additional cost of operation and maintenance occasioned thereby, shall be paid by Tenant to Landlord upon demand by Landlord. 

  
 -13-

 (e) Telecommunications. Upon request from Tenant from time to time, Landlord will
provide Tenant with a listing of telecommunications and media service providers serving the Project, and Tenant shall have the right to contract directly with the providers of its choice. If Tenant wishes to contract with or obtain service from any
provider which does not currently serve the Project or wishes to obtain from an existing carrier services which will require the installation of additional equipment, such provider must, prior to providing service, enter into a written agreement
with Landlord setting forth the terms and conditions of the access to be granted to such provider. In considering the installation of any new or additional telecommunications cabling or equipment at the Project, Landlord will consider all relevant
factors in a reasonable and non-discriminatory manner, including, without limitation, the existing availability of services at the Project, the impact of the proposed installations upon the Project and its operations and the available space and
capacity for the proposed installations. Landlord may also consider whether the proposed service may result in interference with or interruption of other services at the Project or the business operations of other tenants or occupants of the
Project. In no event shall Landlord be obligated to incur any costs or liabilities in connection with the installation or delivery of telecommunication services or facilities at the Project. All such installations shall be subject to Landlord’s
prior approval and shall be performed in accordance with the terms of Article 9. If Landlord approves the proposed installations in accordance with the foregoing, Landlord will deliver its standard form agreement upon request and will use
commercially reasonable efforts to promptly enter into an agreement on reasonable and non-discriminatory terms with a qualified, licensed and reputable carrier confirming the terms of installation and operation of telecommunications equipment
consistent with the foregoing. Notwithstanding the foregoing, Landlord acknowledges that Tenant will have the right to use Cox Cable as its telecommunications provider for the Premises and Landlord will reasonably cooperate with Tenant and Cox Cable
to grant to Cox Cable access to the Premises to provide such services. 
 (f) After-Hours Use. If Tenant requires
heating, ventilation and/or air conditioning during times other than the times provided in Section 11(a) above, Tenant shall give Landlord such advance notice as Landlord shall reasonably require and shall pay Landlord’s standard charge
for such after-hours use, which charge shall be an amount equal to Landlord’s reasonable estimate of Landlord’s actual cost to provide such after-hours heating, ventilation and/or air conditioning services. Tenant shall have after-hours
access to the Project and will be provided with access key cards for such after-hours access in an amount reasonably required by Tenant in accordance with Section 26(f) of the Rules and Regulations. 

ARTICLE 12 
 RIGHTS OF LANDLORD 
 (a) Right of Entry. Landlord and its
agents shall have the right to enter the Premises at all reasonable times for the purpose of cleaning the Premises, examining or inspecting the same, serving or posting and keeping posted thereon notices as provided by law, or which Landlord deems
necessary for the protection of Landlord or the Project, showing the same to prospective tenants, lenders or purchasers of the Project, in the case of an emergency, and for making such alterations, repairs, improvements or additions to the Premises
or to the Project as Landlord may deem necessary or desirable. If Tenant shall not be personally present to open and permit an entry into the Premises at any time when such an entry by Landlord is necessary or permitted hereunder, Landlord may enter
by means of a master key, or may forcibly enter in the case of an emergency, in each event without liability to Tenant and without affecting this Lease. 
 (b) Maintenance Work. Landlord reserves the right from time to time, but subject to payment by and/or reimbursement from Tenant as otherwise provided herein: (i) to install, use, maintain,
repair, replace, relocate and control for service to the Premises and/or other parts of the Project pipes, ducts, conduits, wires, cabling, appurtenant fixtures, equipment spaces and mechanical systems, wherever located in the Premises or the
Project, (ii) to alter, close or relocate any facility in the Premises or the common areas or otherwise conduct any of the above activities for the purpose of complying with a general plan for fire/life safety for the Project or otherwise, and
(iii) to comply with any federal, state or local law, rule or order. Landlord shall attempt to perform any such work with the least inconvenience to Tenant as is reasonably practicable, but in no event shall Tenant be permitted to withhold or
reduce Basic Rental or other charges due hereunder as a result of same, make any claim for constructive eviction or otherwise make any claim against Landlord for interruption or interference with Tenant’s business and/or operations. 

  
 -14-

 (c) Rooftop. If Tenant desires to use the rooftop of the Project for any purpose,
including the installation of communication equipment to be used from the Premises, such rights will be granted in Landlord’s sole discretion and Tenant must negotiate the terms of any rooftop access with Landlord or the rooftop management
company or lessee holding rights to the rooftop from time to time. Any rooftop access granted to Tenant will be at prevailing rates and will be governed by the terms of a separate written agreement or an amendment to this Lease. 

ARTICLE 13 
 INDEMNITY; EXEMPTION OF LANDLORD FROM LIABILITY 
 (a)
Indemnity. Tenant shall indemnify, defend and hold Landlord, Arden Realty, Inc., their subsidiaries, partners, parental or other affiliates and their respective members, shareholders, officers, directors, employees and contractors
(collectively, “Landlord Parties”) harmless from any and all claims arising from Tenant’s use of the Premises or the Project or from the conduct of its business or from any activity, work or thing which may be permitted or
suffered by Tenant in or about the Premises or the Project and shall further indemnify, defend and hold Landlord and the Landlord Parties harmless from and against any and all claims arising from any breach or default in the performance of any
obligation on Tenant’s part to be performed under this Lease or arising from any negligence or willful misconduct of Tenant or any of its agents, contractors, employees or invitees, patrons, customers or members in or about the Project and from
any and all costs, attorneys’ fees and costs, expenses and liabilities incurred in the defense of any claim or any action or proceeding brought thereon, including negotiations in connection therewith. Tenant hereby assumes all risk of damage to
property or injury to persons in or about the Premises from any cause, and Tenant hereby waives all claims in respect thereof against Landlord and the Landlord Parties, excepting where the damage is caused solely by the gross negligence or willful
misconduct of Landlord or the Landlord Parties. 
 (b) Exemption of Landlord from Liability. Landlord and the Landlord
Parties shall not be liable for injury to Tenant’s business, or loss of income therefrom, however occurring (including, without limitation, from any failure or interruption of services or utilities or as a result of Landlord’s negligence),
or, except in connection with damage or injury resulting from the gross negligence or willful misconduct of Landlord or the Landlord Parties, for damage that may be sustained by the person, goods, wares, merchandise or property of Tenant, its
employees, invitees, customers, agents, or contractors, or any other person in, on or about the Premises directly or indirectly caused by or resulting from any cause whatsoever, including, but not limited to, fire, steam, electricity, gas, water, or
rain which may leak or flow from or into any part of the Premises, or from the breakage, leakage, obstruction or other defects of the pipes, sprinklers, wires, appliances, plumbing, air conditioning, light fixtures, or mechanical or electrical
systems, or from intrabuilding cabling or wiring, whether such damage or injury results from conditions arising upon the Premises or upon other portions of the Project or from other sources or places and regardless of whether the cause of such
damage or injury or the means of repairing the same is inaccessible to Tenant. Landlord and the Landlord Parties shall not be liable to Tenant for any damages arising from any willful or negligent action or inaction of any other tenant of the
Project. 
 (c) Security. Tenant acknowledges that Landlord’s election whether or not to provide any type of
mechanical surveillance or security personnel whatsoever in the Project is solely within Landlord’s discretion; Landlord and the Landlord Parties shall have no duty or liability in connection with the provision, or lack, of such services, and
Tenant hereby agrees to hold Landlord and the Landlord Parties harmless with regard to any such potential claim. Landlord and the Landlord Parties shall not be liable for losses due to theft, vandalism, or like causes. Tenant shall defend,
indemnify, and hold Landlord and the Landlord Parties harmless from and against any such claims made by any employee, licensee, invitee, contractor, agent or other person whose presence in, on or about the Premises or the Project is attendant to the
business of Tenant. 
 ARTICLE 14 
 INSURANCE 
 (a) Tenant’s Insurance. Tenant, shall at all
times during the Term of this Lease, and at its own cost and expense, procure and continue in force the following insurance coverage: (i) Commercial General Liability Insurance, written on an occurrence basis, with a combined single limit for
bodily injury and property damages of not less than Two Million Dollars 

  
 -15-

 
($2,000,000) per occurrence and Three Million Dollars ($3,000,000) in the annual aggregate, including products liability coverage if applicable, owners and contractors protective coverage,
blanket contractual coverage including both oral and written contracts, and personal injury coverage, covering the insuring provisions of this Lease and the performance of Tenant of the indemnity and exemption of Landlord from liability agreements
set forth in Article 13 hereof; (ii) a policy of standard fire, extended coverage and special extended coverage insurance (all risks), including a vandalism and malicious mischief endorsement, sprinkler leakage coverage and earthquake
sprinkler leakage where sprinklers are provided in an amount equal to the full replacement value new without deduction for depreciation of all (A) Tenant Improvements, Alterations, fixtures and other improvements in the Premises, including but
not limited to all mechanical, plumbing, heating, ventilating, air conditioning, electrical, telecommunication and other equipment, systems and facilities, and (B) trade fixtures, furniture, equipment and other personal property installed by or
at the expense of Tenant; (iii) Worker’s Compensation coverage as required by law; and (iv) business interruption, loss of income and extra expense insurance covering any failure or interruption of Tenant’s business equipment
(including, without limitation, telecommunications equipment) and covering all other perils, failures or interruptions sufficient to cover a period of interruption of not less than twelve (12) months. Tenant shall carry and maintain during the
entire Term (including any option periods, if applicable), at Tenant’s sole cost and expense, increased amounts of the insurance required to be carried by Tenant pursuant to this Article 14 and such other reasonable types of insurance
coverage and in such reasonable amounts covering the Premises and Tenant’s operations therein, as may be reasonably required by Landlord. 
 (b) Form of Policies. The aforementioned minimum limits of policies and Tenant’s procurement and maintenance thereof shall in no event limit the liability of Tenant hereunder. The Commercial
General Liability Insurance policy shall name Landlord, the Landlord Parties, Landlord’s property manager, Landlord’s lender(s) and such other persons or firms as Landlord specifies from time to time, as additional insureds with an
appropriate endorsement to the policy(s). All such insurance policies carried by Tenant shall be with companies having a rating of not less than A-VIII in Best’s Insurance Guide. Tenant shall furnish to Landlord, from the insurance companies,
or cause the insurance companies to furnish, certificates of coverage. The deductible under each such policy shall be reasonably acceptable to Landlord. No such policy shall be cancelable or subject to reduction of coverage or other modification or
cancellation except after thirty (30) days prior written notice to Landlord by the insurer. All such policies shall be endorsed to agree that Tenant’s policy is primary and that any insurance carried by Landlord is excess and not
contributing with any Tenant insurance requirement hereunder. Tenant shall, at least twenty (20) days prior to the expiration of such policies, furnish Landlord with renewals or binders. Tenant agrees that if Tenant does not take out and
maintain such insurance or furnish Landlord with renewals or binders in a timely manner, Landlord may (but shall not be required to) procure said insurance on Tenant’s behalf and charge Tenant the cost thereof, which amount shall be payable by
Tenant upon demand with interest (at the rate set forth in Section 20(e) below) from the date such sums are expended. Tenant shall have the right to provide such insurance coverage pursuant to blanket policies obtained by Tenant, provided such
blanket policies expressly afford coverage to the Premises and to Tenant as required by this Lease. 
 (c) Landlord’s
Insurance. Landlord may, as a cost to be included in Operating Costs, procure and maintain at all times during the Term of this Lease, a policy or policies of insurance covering loss or damage to the Project in the amount of the full replacement
cost without deduction for depreciation thereof, providing protection against all perils included within the classification of fire and extended coverage, vandalism coverage and malicious mischief, sprinkler leakage, water damage, and special
extended coverage on the building. Additionally, Landlord may carry: (i) Bodily Injury and Property Damage Liability Insurance and/or Excess Liability Coverage Insurance; and (ii) Earthquake and/or Flood Damage Insurance; and
(iii) Rental Income Insurance; and (iv) any other forms of insurance Landlord may deem appropriate or any lender may require. The costs of all insurance carried by Landlord shall be included in Operating Costs. 

(d) Waiver of Subrogation. Landlord and Tenant each agree to require their respective insurers issuing the insurance described in
Sections 14(a)(ii), 14(a)(iv) and the first sentence of Section 14(c), to waive any rights of subrogation that such companies may have against the other party. Tenant hereby waives any right that Tenant may have against Landlord

  
 -16-

 
and Landlord hereby waives any right that Landlord may have against Tenant as a result of any loss or damage to the extent such loss or damage is insurable under such policies. 

(e) Compliance with Insurance Requirements. Tenant agrees that it will not, at any time, during the Term of this Lease, carry any
stock of goods or do anything in or about the Premises that will in any way tend to increase the insurance rates upon the Project. Tenant agrees to pay Landlord forthwith upon demand the amount of any increase in premiums for insurance that may be
carried during the Term of this Lease, or the amount of insurance to be carried by Landlord on the Project resulting from the foregoing, or from Tenant doing any act in or about the Premises that does so increase the insurance rates, whether or not
Landlord shall have consented to such act on the part of Tenant. If Tenant installs upon the Premises any electrical equipment which causes an overload of electrical lines of the Premises, Tenant shall at its own cost and expense, in accordance with
all other Lease provisions (specifically including, but not limited to, the provisions of Article 9, 10 and 11 hereof), make whatever changes are necessary to comply with requirements of the insurance underwriters and any governmental authority
having jurisdiction thereover, but nothing herein contained shall be deemed to constitute Landlord’s consent to such overloading. Tenant shall, at its own expense, comply with all insurance requirements applicable to the Premises including,
without limitation, the installation of fire extinguishers or an automatic dry chemical extinguishing system. 
 ARTICLE 15

 ASSIGNMENT AND SUBLETTING 
 Tenant shall have no power to, either voluntarily, involuntarily, by operation of law or otherwise, sell, assign, transfer or hypothecate this Lease, or sublet the Premises or any part thereof, or permit
the Premises or any part thereof to be used or occupied by anyone other than Tenant or Tenant’s employees, officers, directors, and agents without the prior written consent of Landlord, which consent shall not be unreasonably withheld. Tenant
may transfer its interest pursuant to this Lease only upon the following express conditions, which conditions are agreed by Landlord and Tenant to be reasonable: 
 (a) That the proposed Transferee (as hereafter defined) shall be subject to the prior written consent of Landlord, which consent will not be unreasonably withheld but, without limiting the generality of
the foregoing, it shall be reasonable for Landlord to deny such consent if: 
 (i) The use to be made of the Premises by the
proposed Transferee is (A) not generally consistent with the character and nature of all other tenancies in the Project, or (B) a use which conflicts with any so-called “exclusive” then in favor of another tenant of the Project
or any other buildings which are in the same complex as the Project, or (C) a use that is not compatible with the existing certification or a planned future certification of the Project under the LEED rating system (or other applicable
certification standard), or (D) a use which would be prohibited by any other portion of this Lease (including but not limited to any Rules and Regulations then in effect); 

(ii) The financial responsibility of the proposed Transferee is not reasonably satisfactory to Landlord; 

(iii) The proposed Transferee is either a governmental agency or instrumentality thereof; or 

(iv) Either the proposed Transferee or any person or entity which directly or indirectly controls, is controlled by or is under common
control with the proposed Transferee (A) occupies space in the Project at the time of the request for consent, or (B) is negotiating with Landlord or has negotiated with Landlord during the six (6) month period immediately preceding
the date of the proposed Transfer, to lease space in the Project. 
 (b) Upon Tenant’s submission of a request for
Landlord’s consent to any such Transfer, Tenant shall pay to Landlord Landlord’s then standard processing fee and reasonable attorneys’ fees and costs incurred in connection with the proposed Transfer, which the parties hereby
stipulate to be $1,000.00, unless Landlord provides to Tenant evidence that Landlord has incurred greater costs in connection with the proposed Transfer; 

  
 -17-

 (c) That the proposed Transferee shall execute an agreement pursuant to which it shall agree
to perform faithfully and be bound by all of the terms, covenants, conditions, provisions and agreements of this Lease applicable to that portion of the Premises so transferred; and 

(d) That an executed duplicate original of said assignment and assumption agreement or other Transfer on a form reasonably approved by
Landlord, shall be delivered to Landlord within five (5) days after the execution thereof, and that such Transfer shall not be binding upon Landlord until the delivery thereof to Landlord and the execution and delivery of Landlord’s
consent thereto. It shall be a condition to Landlord’s consent to any subleasing, assignment or other transfer of part or all of Tenant’s interest in the Premises (“Transfer”) that (i) upon Landlord’s consent to
any Transfer, Tenant shall pay and continue to pay Landlord fifty percent (50%) of any “Transfer Premium” (defined below), received by Tenant from the transferee; (ii) any sublessee of part or all of Tenant’s interest in the
Premises shall agree that in the event Landlord gives such sublessee notice that Tenant is in default under this Lease, such sublessee shall thereafter make all sublease or other payments directly to Landlord, which will be received by Landlord
without any liability whether to honor the sublease or otherwise (except to credit such payments against sums due under this Lease), and any sublessee shall agree to attorn to Landlord or its successors and assigns at their request should this Lease
be terminated for any reason, except that in no event shall Landlord or its successors or assigns be obligated to accept such attornment; (iii) any such Transfer and consent shall be effected on forms supplied by Landlord and/or its legal
counsel; (iv) Landlord may require that Tenant not then be in default beyond any applicable cure period hereunder in any respect; and (v) Tenant or the proposed subtenant or assignee (collectively, “Transferee”) shall
agree to pay Landlord, upon demand, as Additional Rent, a sum equal to the additional costs, if any, incurred by Landlord for maintenance and repair as a result of any change in the nature of occupancy caused by such subletting or assignment.
“Transfer Premium” shall mean all rent, Additional Rent or other consideration payable by a Transferee in connection with a Transfer in excess of the Basic Rental and Direct Costs payable by Tenant under this Lease during the term
of the Transfer and if such Transfer is for less than all of the Premises, the Transfer Premium shall be calculated on a rentable square foot basis. The calculation of “Transfer Premium” shall also include, but not be limited to, key
money, bonus money or other cash consideration paid by a Transferee to Tenant in connection with such Transfer, and any payment in excess of fair market value for services rendered by Tenant to the Transferee and any payment in excess of fair market
value for assets, fixtures, inventory, equipment, or furniture transferred by Tenant to the Transferee in connection with such Transfer. Any Transfer of this Lease which is not in compliance with the provisions of this Article 15 shall be
voidable by written notice from Landlord and shall, at the option of Landlord, terminate this Lease. In no event shall the consent by Landlord to any Transfer be construed as relieving Tenant or any Transferee from obtaining the express written
consent of Landlord to any further Transfer, or as releasing Tenant from any liability or obligation hereunder whether or not then accrued and Tenant shall continue to be fully liable therefor. No collection or acceptance of rent by Landlord from
any person other than Tenant shall be deemed a waiver of any provision of this Article 15 or the acceptance of any Transferee hereunder, or a release of Tenant (or of any Transferee of Tenant). Notwithstanding anything to the contrary in this
Lease, if Tenant or any proposed Transferee claims that Landlord has unreasonably withheld or delayed its consent under this Article 15 or otherwise has breached or acted unreasonably under this Article 15, their sole remedies shall be a
declaratory judgment and an injunction for the relief sought without any monetary damages, and Tenant hereby waives all other remedies, including, without limitation, any right at law or equity to terminate this Lease, on its own behalf and, to the
extent permitted under all applicable laws, on behalf of the proposed Transferee. 
 Notwithstanding anything to the contrary
contained in this Article 15, an assignment or subletting of all or a portion of the Premises to an affiliate (“Affiliate”) of Tenant (an entity which is controlled by, controls, or is under common control with, Tenant or that
acquires all or substantially all of Tenant’s assets or business), shall not be deemed a Transfer under this Article 15, provided that Tenant notifies Landlord of any such assignment or sublease and promptly supplies Landlord with any
documents or information requested by Landlord regarding such assignment or sublease or such affiliate, and further provided that (i) such assignment or sublease is not a subterfuge by Tenant to avoid its obligations under this Lease, and
(ii) Landlord confirms that such assignee or subtenant does not violate Landlord’s “know your customer” requirements. An assignee of Tenant’s entire interest in this Lease pursuant to the immediately preceding sentence may
be referred to herein as an “Affiliated Assignee.” “Control,” as used in 

  
 -18-

 
this Article 15, shall mean the ownership, directly or indirectly, of greater than fifty percent (50%) of the voting securities of, or possession of the right to vote, in the ordinary
direction of its affairs, of greater than fifty percent (50%) of the voting interest in, an entity. 
 ARTICLE 16

 DAMAGE OR DESTRUCTION 
 If the Project is damaged by fire or other insured casualty and the insurance proceeds have been made available therefor by the holder or holders of any mortgages or deeds of trust covering the Premises
or the Project, the damage shall be repaired by Landlord to the extent such insurance proceeds are available therefor and provided such repairs can, in Landlord’s sole opinion, be completed within one hundred eighty (180) days after the
necessity for repairs as a result of such damage becomes known to Landlord, without the payment of overtime or other premiums, and until such repairs are completed rent shall be abated in proportion to the part of the Premises which is unusable by
Tenant in the conduct of its business (but there shall be no abatement of rent by reason of any portion of the Premises being unusable for a period equal to one (1) day or less). However, if the damage is due to the fault or neglect of Tenant,
its employees, agents, contractors, guests, invitees and the like, there shall be no abatement of rent, unless and to the extent Landlord receives rental income insurance proceeds. Within sixty (60) days after the date Landlord learns of the
necessity for repairs as a result of damage, Landlord shall notify Tenant (“Damage Repair Estimate”) of Landlord’s estimated assessment of the period of time in which the repairs will be completed. Upon the occurrence of any
damage to the Premises, Tenant shall assign to Landlord (or to any party designated by Landlord) all insurance proceeds payable to Tenant under Section 14(a)(ii)(A) above; provided, however, that if the cost of repair of improvements within the
Premises by Landlord exceeds the amount of insurance proceeds received by Landlord from Tenant’s insurance carrier, as so assigned by Tenant, such excess costs shall be paid by Tenant to Landlord prior to Landlord’s repair of such damage.
If the Damage Repair Estimate indicates that repairs cannot, in Landlord’s opinion, be completed within one hundred eighty (180) days after the necessity for repairs as a result of such damage becomes known to Landlord without the payment
of overtime or other premiums, Landlord may, at its option, either (i) make such repairs in a reasonable time and in such event this Lease shall continue in effect and the rent shall be abated, if at all, in the manner provided in this
Article 16, or (ii) elect not to effect such repairs and instead terminate this Lease, by notifying Tenant in writing of such termination within sixty (60) days after Landlord learns of the necessity for repairs as a result of damage,
such notice to include a termination date giving Tenant sixty (60) days to vacate the Premises. In addition, Landlord may elect to terminate this Lease if the Project shall be damaged by fire or other casualty or cause, whether or not the
Premises are affected, if the damage is not fully covered, except for deductible amounts, by Landlord’s insurance policies. However, if Landlord does not elect to terminate this Lease pursuant to Landlord’s termination right as provided
above, and if the Damage Repair Estimate indicates that repairs cannot be completed within one hundred eighty (180) days after being commenced and if such damage is not the result of the negligence or willful misconduct of Tenant or
Tenant’s employees, licensees, invitees or agents, Tenant may elect, not later than thirty (30) days after Tenant’s receipt of the Damage Repair Estimate, to terminate this Lease by written notice to Landlord effective as of the date
specified in Tenant’s notice. Finally, if the Premises or the Project is damaged to any substantial extent during the last twelve (12) months of the Term, then notwithstanding anything contained in this Article 16 to the contrary,
Landlord shall have the option to terminate this Lease by giving written notice to Tenant of the exercise of such option within sixty (60) days after Landlord learns of the necessity for repairs as the result of such damage. In the event that
the Premises or the Project is destroyed or damaged to any substantial extent during the last twelve (12) months of the Lease Term and if such damage shall take longer than sixty (60) days to repair and if such damage is not the result of
the negligence or willful misconduct of Tenant or Tenant’s employees, licensees, invitees or agents, then notwithstanding anything in this Article 16 to the contrary, Tenant shall have the option to terminate this Lease by written notice
to Landlord of the exercise of such option within sixty (60) days after Tenant learns of the necessity for repairs as the result of such damage. A total destruction of the Project shall automatically terminate this Lease. Except as provided in
this Article 16, there shall be no abatement of rent and no liability of Landlord by reason of any injury to or interference with Tenant’s business or property arising from such damage or destruction or the making of any repairs,
alterations or improvements in or to any portion of the Project or the Premises or in or to fixtures, appurtenances and equipment therein. Tenant understands that Landlord will not carry insurance of any kind on Tenant’s furniture, furnishings,
trade fixtures or equipment, and that 

  
 -19-

 
Landlord shall not be obligated to repair any damage thereto or replace the same. Tenant acknowledges that Tenant shall have no right to any proceeds of insurance carried by Landlord relating to
property damage. With respect to any damage which Landlord is obligated to repair or elects to repair, Tenant, as a material inducement to Landlord entering into this Lease, irrevocably waives and releases its rights under the provisions of
Sections 1932 and 1933 of the California Civil Code. 
 ARTICLE 17 

SUBORDINATION 
 This Lease is subject to, and Tenant agrees to comply with, all matters of record affecting the Real Property. This Lease is also subject and subordinate to all ground or underlying leases, mortgages and
deeds of trust which affect the Real Property, including all renewals, modifications, consolidations, replacements and extensions thereof; provided, however, if the lessor under any such lease or the holder or holders of any such mortgage or deed of
trust shall advise Landlord that they desire or require this Lease to be prior and superior thereto, upon written request of Landlord to Tenant, Tenant agrees to promptly execute, acknowledge and deliver any and all documents or instruments which
Landlord or such lessor, holder or holders deem necessary or desirable for purposes thereof. Landlord shall have the right to cause this Lease to be and become and remain subject and subordinate to any and all ground or underlying leases, mortgages
or deeds of trust which may hereafter be executed covering the Premises, the Project or the property or any renewals, modifications, consolidations, replacements or extensions thereof, for the full amount of all advances made or to be made
thereunder and without regard to the time or character of such advances, together with interest thereon and subject to all the terms and provisions thereof; provided, however, that Landlord obtains from the lender or other party in question a
written undertaking in favor of Tenant to the effect that such lender or other party will not disturb Tenant’s right of possession under this Lease if Tenant is not then or thereafter in breach of any covenant or provision of this Lease. Tenant
agrees, within ten (10) days after Landlord’s written request therefor, to execute, acknowledge and deliver upon request any and all documents or instruments requested by Landlord or necessary or proper to assure the subordination of this
Lease to any such mortgages, deed of trust, or leasehold estates (hereinafter, an “SNDA”). Tenant agrees that in the event any proceedings are brought for the foreclosure of any mortgage or deed of trust or any deed in lieu thereof,
to attorn to the purchaser or any successors thereto upon any such foreclosure sale or deed in lieu thereof as so requested to do so by such purchaser and to recognize such purchaser as the lessor under this Lease; Tenant shall, within five
(5) days after request execute such further instruments or assurances as such purchaser may reasonably deem necessary to evidence or confirm such attornment. Tenant agrees to provide copies of any notices of Landlord’s default under this
Lease to any mortgagee or deed of trust beneficiary whose address has been provided to Tenant and Tenant shall provide such mortgagee or deed of trust beneficiary a commercially reasonable time after receipt of such notice within which to cure any
such default. Tenant waives the provisions of any current or future statute, rule or law which may give or purport to give Tenant any right or election to terminate or otherwise adversely affect this Lease and the obligations of the Tenant hereunder
in the event of any foreclosure proceeding or sale. 
 ARTICLE 18 

EMINENT DOMAIN 
 If the whole of the Premises or the Project or so much thereof as to render the balance unusable by Tenant shall be taken under power of eminent domain, or is sold, transferred or conveyed in lieu
thereof, this Lease shall automatically terminate as of the date of such condemnation, or as of the date possession is taken by the condemning authority, at Landlord’s option. No award for any partial or entire taking shall be apportioned, and
Tenant hereby assigns to Landlord any award which may be made in such taking or condemnation, together with any and all rights of Tenant now or hereafter arising in or to the same or any part thereof; provided, however, that nothing contained herein
shall be deemed to give Landlord any interest in or to require Tenant to assign to Landlord any award made to Tenant for the taking of personal property and trade fixtures belonging to Tenant and removable by Tenant at the expiration of the Term
hereof as provided hereunder or for the interruption of, or damage to, Tenant’s business. In the event of a partial taking described in this Article 18, or a sale, transfer or conveyance in lieu thereof, which does not result in a
termination of this Lease, the rent shall be apportioned according to the ratio that the part of the Premises remaining useable by Tenant bears to the total 

  
 -20-

 
area of the Premises. Tenant hereby waives any and all rights it might otherwise have pursuant to Section 1265.130 of the California Code of Civil Procedure. 

ARTICLE 19 
 DEFAULT 
 Each of the following acts or omissions of Tenant or of
any guarantor of Tenant’s performance hereunder, or occurrences, shall constitute an “Event of Default”: 

(a) Failure or refusal to pay Basic Rental, Additional Rent or any other amount to be paid by Tenant to Landlord hereunder within three
(3) calendar days after notice that the same is due or payable hereunder; said three (3) day period shall be in lieu of, and not in addition to, the notice requirements of Section 1161 of the California Code of Civil Procedure or any
similar or successor law; 
 (b) Except as set forth in items (a) above and (c) through and including (g) below,
failure to perform or observe any other covenant or condition of this Lease to be performed or observed within thirty (30) days following written notice to Tenant of such failure. Such thirty (30) day notice shall be in lieu of, and not in
addition to, any required under Section 1161 of the California Code of Civil Procedure or any similar or successor law; 

(c) Abandonment or vacating or failure to accept tender of possession of the Premises or any significant portion thereof unless Tenant is
marketing the Premises for sublease; 
 (d) The taking in execution or by similar process or law (other than by eminent domain)
of the estate hereby created; 
 (e) The filing by Tenant or any guarantor hereunder in any court pursuant to any statute of a
petition in bankruptcy or insolvency or for reorganization or arrangement for the appointment of a receiver of all or a portion of Tenant’s property; the filing against Tenant or any guarantor hereunder of any such petition, or the commencement
of a proceeding for the appointment of a trustee, receiver or liquidator for Tenant, or for any guarantor hereunder, or of any of the property of either, or a proceeding by any governmental authority for the dissolution or liquidation of Tenant or
any guarantor hereunder, if such proceeding shall not be dismissed or trusteeship discontinued within thirty (30) days after commencement of such proceeding or the appointment of such trustee or receiver; or the making by Tenant or any
guarantor hereunder of an assignment for the benefit of creditors. Tenant hereby stipulates to the lifting of the automatic stay in effect and relief from such stay for Landlord in the event Tenant files a petition under the United States Bankruptcy
laws, for the purpose of Landlord pursuing its rights and remedies against Tenant and/or a guarantor of this Lease; 
 (f)
Tenant’s failure to cause to be released any mechanics liens filed against the Premises or the Project within twenty (20) days after the date the same shall have been filed or recorded; or 

(g) Tenant’s failure to observe or perform according to the provisions of Section 4(b)(i) and Articles 7, 14, 17 or 25
within two (2) business days after notice from Landlord. 
 All defaults by Tenant of any covenant or condition of this
Lease shall be deemed by the parties hereto to be material. 
 ARTICLE 20 

REMEDIES 
 (a) Upon the occurrence of an Event of Default under this Lease as provided in Article 19 hereof, Landlord may exercise all of its remedies as may be permitted by law, including but not limited to
the remedy provided by Section 1951.4 of the California Civil Code, and including without limitation, terminating this Lease, reentering the Premises and removing all persons and property therefrom, which property may be stored by Landlord at a
warehouse or elsewhere at the risk, expense and for the account of Tenant. If Landlord elects to terminate this Lease, Landlord shall be entitled to recover from Tenant the aggregate of all amounts permitted by law, including but not limited to
(i) the worth at the time of award of the amount of any unpaid rent which had been earned at the time of such termination; plus (ii) the worth at the time of award of the amount by which the unpaid rent which would have been earned after

  
 -21-

 
termination until the time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus (iii) the worth at the time of award of the amount by
which the unpaid rent for the balance of the Term after the time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus (iv) any other amount necessary to compensate Landlord for all the
detriment proximately caused by Tenant’s failure to perform its obligations under this Lease or which in the ordinary course of things would be likely to result therefrom, specifically including but not limited to, tenant improvement expenses,
brokerage commissions and advertising expenses incurred, expenses of remodeling the Premises or any portion thereof for a new tenant, whether for the same or a different use, and any special concessions made to obtain a new tenant; and (v) at
Landlord’s election, such other amounts in addition to or in lieu of the foregoing as may be permitted from time to time by applicable law. The term “rent” as used in this Section 20(a) shall be deemed to be and to mean all sums
of every nature required to be paid by Tenant pursuant to the terms of this Lease, whether to Landlord or to others. As used in items (i) and (ii), above, the “worth at the time of award” shall be computed by allowing interest at the
rate set forth in item (e), below, but in no case greater than the maximum amount of such interest permitted by law. As used in item (iii), above, the “worth at the time of award” shall be computed by discounting such amount at
the discount rate of the Federal Reserve Bank of San Francisco at the time of award plus one percent (1%). 
 (b) Nothing in
this Article 20 shall be deemed to affect Landlord’s right to indemnification for liability or liabilities arising prior to the termination of this Lease for personal injuries or property damage under the indemnification clause or clauses
contained in this Lease. 
 (c) Notwithstanding anything to the contrary set forth herein, Landlord’s re-entry to perform
acts of maintenance or preservation of or in connection with efforts to relet the Premises or any portion thereof, or the appointment of a receiver upon Landlord’s initiative to protect Landlord’s interest under this Lease shall not
terminate Tenant’s right to possession of the Premises or any portion thereof and, until Landlord does elect to terminate this Lease, this Lease shall continue in full force and effect and Landlord may enforce all of Landlord’s rights and
remedies hereunder including, without limitation, the remedy described in California Civil Code Section 1951.4 (lessor may continue lease in effect after lessee’s breach and abandonment and recover rent as it becomes due, if lessee has the
right to sublet or assign, subject only to reasonable limitations). Accordingly, if Landlord does not elect to terminate this Lease on account of any default by Tenant, Landlord may, from time to time, without terminating this Lease, enforce all of
its rights and remedies under this Lease, including the right to recover all rent as it becomes due. 
 (d) All rights, powers
and remedies of Landlord hereunder and under any other agreement now or hereafter in force between Landlord and Tenant shall be cumulative and not alternative and shall be in addition to all rights, powers and remedies given to Landlord by law, and
the exercise of one or more rights or remedies shall not impair Landlord’s right to exercise any other right or remedy. 
 (e) Any amount due from Tenant to Landlord hereunder which is not paid when due shall bear interest at the lower of eighteen percent (18%) per annum or the maximum lawful rate of interest from the
due date until paid, unless otherwise specifically provided herein, but the payment of such interest shall not excuse or cure any default by Tenant under this Lease. In addition to such interest: (i) if Basic Rental is not paid on or before the
fifth (5th) day of the calendar month for which the
same is due, a late charge equal to five percent (5%) of the amount overdue or $100, whichever is greater, shall be immediately due and owing and shall accrue for each calendar month or part thereof until such rental, including the late charge,
is paid in full, which late charge Tenant hereby agrees is a reasonable estimate of the damages Landlord shall suffer as a result of Tenant’s late payment and (ii) an additional charge of $25 shall be assessed for any check given to
Landlord by or on behalf of Tenant which is not honored by the drawee thereof; which damages include Landlord’s additional administrative and other costs associated with such late payment and unsatisfied checks and the parties agree that it
would be impracticable or extremely difficult to fix Landlord’s actual damage in such event. Such charges for interest and late payments and unsatisfied checks are separate and cumulative and are in addition to and shall not diminish or
represent a substitute for any or all of Landlord’s rights or remedies under any other provision of this Lease. 

  
 -22-

 (f) In the event of any default, breach or violation of Tenant’s rights under this
Lease by Landlord, Tenant’s exclusive remedies shall be an action for specific performance or action for actual damages. Without limiting any other waiver by Tenant which may be contained in this Lease, Tenant hereby waives the benefit of any
law granting it the right to perform Landlord’s obligation, or the right to terminate this Lease on account of any Landlord default. 
 ARTICLE 21 
 TRANSFER OF LANDLORD’S INTEREST

 In the event of any transfer or termination of Landlord’s interest in the Premises or the Project by sale,
assignment, transfer, foreclosure, deed-in-lieu of foreclosure or otherwise whether voluntary or involuntary, Landlord shall be automatically relieved of any and all obligations and liabilities on the part of Landlord from and after the date of such
transfer or termination, including furthermore without limitation, the obligation of Landlord under Article 4 and California Civil Code 1950.7 above to return the cash security deposit and Letter of Credit, provided said cash security deposit
and Letter of Credit are transferred to said transferee. Tenant agrees to attorn to the transferee upon any such transfer and to recognize such transferee as the lessor under this Lease and Tenant shall, within five (5) days after request,
execute such further instruments or assurances as such transferee may reasonably deem necessary to evidence or confirm such attornment. 
 ARTICLE 22 
 BROKER 

In connection with this Lease, Tenant warrants and represents that it has had dealings only with firm(s) set forth in Article 1.I.
of the Basic Lease Provisions and that it knows of no other person or entity who is or might be entitled to a commission, finder’s fee or other like payment in connection herewith and does hereby indemnify and agree to hold Landlord, its
agents, members, partners, representatives, officers, affiliates, shareholders, employees, successors and assigns harmless from and against any and all loss, liability and expenses that Landlord may incur should such warranty and representation
prove incorrect, inaccurate or false. 
 ARTICLE 23 

PARKING 
 Tenant shall be entitled to use, commencing on the Commencement Date, the number of unreserved parking passes set forth in Article 1.J. of the Basic Lease Provisions, which parking passes shall
pertain to the Project parking facility. Tenant shall not be required to pay to Landlord any fee for such unreserved parking passes during the initial Term of this Lease; however, Tenant shall be responsible for the full amount of any taxes imposed
by any governmental authority in connection with the use of such parking passes by Tenant or the use of the parking facility by Tenant. Tenant’s continued right to use the parking passes is conditioned upon Tenant abiding by all rules and
regulations which are prescribed from time to time for the orderly operation and use of the parking facility where the parking passes are located, including any sticker or other identification system established by Landlord, Tenant’s
cooperation in seeing that Tenant’s employees and visitors also comply with such rules and regulations, and Tenant not being in default under this Lease. Landlord specifically reserves the right to change the size, configuration, design, layout
and all other aspects of the Project parking facility at any time and Tenant acknowledges and agrees that Landlord may, without incurring any liability to Tenant and without any abatement of rent under this Lease, from time to time, close-off or
restrict access to the Project parking facility for purposes of permitting or facilitating any such construction, alteration or improvements. Landlord may, from time to time, relocate any reserved parking spaces (if any) used by Tenant to another
location in the Project parking facility. Landlord may delegate its responsibilities hereunder to a parking operator or a lessee of the parking facility in which case such parking operator or lessee shall have all the rights of control attributed
hereby to the Landlord. The parking passes used by Tenant pursuant to this Article 23 are provided to Tenant solely for use by Tenant’s own personnel and such passes may not be transferred, assigned, subleased or otherwise alienated by
Tenant without Landlord’s prior approval. 

  
 -23-

 ARTICLE 24 

WAIVER 
 No waiver by Landlord of any provision of this Lease shall be deemed to be a waiver of any other provision hereof or of any subsequent breach by Tenant of the same or any other provision. No provision of
this Lease may be waived by Landlord, except by an instrument in writing executed by Landlord. Landlord’s consent to or approval of any act by Tenant requiring Landlord’s consent or approval shall not be deemed to render unnecessary the
obtaining of Landlord’s consent to or approval of any subsequent act of Tenant, whether or not similar to the act so consented to or approved. No act or thing done by Landlord or Landlord’s agents during the Term of this Lease shall be
deemed an acceptance of a surrender of the Premises, and no agreement to accept such surrender shall be valid unless in writing and signed by Landlord. The subsequent acceptance of rent hereunder by Landlord shall not be deemed to be a waiver of any
preceding breach by Tenant of any term, covenant or condition of this Lease, other than the failure of Tenant to pay the particular rent so accepted, regardless of Landlord’s knowledge of such preceding breach at the time of acceptance of such
rent. Any payment by Tenant or receipt by Landlord of an amount less than the total amount then due hereunder shall be deemed to be in partial payment only thereof and not a waiver of the balance due or an accord and satisfaction, notwithstanding
any statement or endorsement to the contrary on any check or any other instrument delivered concurrently therewith or in reference thereto. Accordingly, Landlord may accept any such amount and negotiate any such check without prejudice to
Landlord’s right to recover all balances due and owing and to pursue its other rights against Tenant under this Lease, regardless of whether Landlord makes any notation on such instrument of payment or otherwise notifies Tenant that such
acceptance or negotiation is without prejudice to Landlord’s rights. 
 ARTICLE 25 

ESTOPPEL CERTIFICATE 
 Tenant shall, at any time and from time to time, upon not less than ten (10) days’ prior written notice from Landlord, execute, acknowledge and deliver to Landlord a statement in writing
certifying the following information, (but not limited to the following information in the event further information is requested by Landlord): (i) that this Lease is unmodified and in full force and effect (or, if modified, stating the nature
of such modification and certifying that this Lease, as modified, is in full force and effect); (ii) the dates to which the rental and other charges are paid in advance, if any; (iii) the amount of Tenant’s cash security deposit and
the Stated Amount of the Letter of Credit, if any; and (iv) acknowledging that there are not, to Tenant’s knowledge, any uncured defaults on the part of Landlord hereunder, and no events or conditions then in existence which, with the
passage of time or notice or both, would constitute a default on the part of Landlord hereunder, or specifying such defaults, events or conditions, if any are claimed. It is expressly understood and agreed that any such statement may be relied upon
by any prospective purchaser or encumbrancer of all or any portion of the Real Property. 
 ARTICLE 26 

LIABILITY OF LANDLORD 
 Notwithstanding anything in this Lease to the contrary, any remedy of Tenant for the collection of a judgment (or other judicial process) requiring the payment of money by Landlord in the event of any
default by Landlord hereunder or any claim, cause of action or obligation, contractual, statutory or otherwise by Tenant against Landlord or the Landlord Parties concerning, arising out of or relating to any matter relating to this Lease and all of
the covenants and conditions or any obligations, contractual, statutory, or otherwise set forth herein, shall be limited solely and exclusively to an amount which is equal to the lesser of (i) the interest of Landlord in and to the Project, and
(ii) the interest Landlord would have in the Project if the Project were encumbered by third party debt in an amount equal to eighty percent (80%) of the then current value of the Project. No other property or assets of Landlord or any
Landlord Party shall be subject to levy, execution or other enforcement procedure for the satisfaction of Tenant’s remedies under or with respect to this Lease, Landlord’s obligations to Tenant, whether contractual, statutory or otherwise,
the relationship of Landlord and Tenant hereunder, or Tenant’s use or occupancy of the Premises. 

  
 -24-

 ARTICLE 27 

INABILITY TO PERFORM 
 This Lease and the obligations of Tenant hereunder shall not be affected or impaired because Landlord is unable to fulfill any of its obligations hereunder or is delayed in doing so, if such inability or
delay is caused by reason of any prevention, delay, stoppage due to strikes, lockouts, acts of God, terrorism, evacuation or any other cause previously, or at such time, beyond the reasonable control or anticipation of Landlord (collectively, a
“Force Majeure”) and Landlord’s obligations under this Lease shall be forgiven and suspended by any such Force Majeure. 
 ARTICLE 28 
 HAZARDOUS WASTE 

(a) Tenant shall not cause or permit any Hazardous Material (as defined in Section 28(d) below) to be brought, kept or used in or
about the Project by Tenant, its agents, employees, contractors, or invitees. Tenant indemnifies Landlord and the Landlord Parties from and against any breach by Tenant of the obligations stated in the preceding sentence, and agrees to defend and
hold Landlord and the Landlord Parties harmless from and against any and all claims, judgments, damages, penalties, fines, costs, liabilities, or losses (including, without limitation, diminution in value of the Project, damages for the loss or
restriction or use of rentable or usable space or of any amenity of the Project, damages arising from any adverse impact or marketing of space in the Project, and sums paid in settlement of claims, attorneys’ fees and costs, consultant fees,
and expert fees) which arise during or after the Term of this Lease as a result of such breach. This indemnification of Landlord and the Landlord Parties by Tenant includes, without limitation, costs incurred in connection with any investigation of
site conditions or any cleanup, remedial, removal, or restoration work required by any federal, state, or local governmental agency or political subdivision because of Hazardous Material present in the soil or ground water on or under the Project.
Without limiting the foregoing, if the presence of any Hazardous Material on the Project caused or permitted by Tenant results in any contamination of the Project, then subject to the provisions of Articles 9, 10 and 11 hereof, Tenant shall
promptly take all actions at its sole expense as are necessary to return the Project to the condition existing prior to the introduction of any such Hazardous Material and the contractors to be used by Tenant for such work must be approved by
Landlord, which approval shall not be unreasonably withheld so long as such actions would not potentially have any material adverse long-term or short-term effect on the Project and so long as such actions do not materially interfere with the use
and enjoyment of the Project by the other tenants thereof; provided however, Landlord shall also have the right, by written notice to Tenant, to directly undertake any such mitigation efforts with regard to Hazardous Materials in or about the
Project due to Tenant’s breach of its obligations pursuant to this Section 28(a), and to charge Tenant, as Additional Rent, for the costs thereof. 
 (b) Landlord and Tenant acknowledge that Landlord may become legally liable for the costs of complying with Laws (as defined in Section 28(e) below) relating to Hazardous Material which are not the
responsibility of Landlord or the responsibility of Tenant, including the following: (i) Hazardous Material present in the soil or ground water on the Project of which Landlord has no knowledge as of the effective date of this Lease;
(ii) a change in Laws which relate to Hazardous Material which make that Hazardous Material which is present on the Real Property as of the effective date of this Lease, whether known or unknown to Landlord, a violation of such new Laws;
(iii) Hazardous Material that migrates, flows, percolates, diffuses, or in any way moves on to, or under, the Project after the effective date of this Lease; or Hazardous Material present on or under the Project as a result of any discharge,
dumping or spilling (whether accidental or otherwise) on the Project by other lessees of the Project or their agents, employees, contractors, or invitees, or by others. Accordingly, Landlord and Tenant agree that the cost of complying with Laws
relating to Hazardous Material on the Project for which Landlord is legally liable and which are paid or incurred by Landlord shall be an Operating Cost (and Tenant shall pay Tenant’s Proportionate Share thereof in accordance with
Article 3) unless the cost of such compliance as between Landlord and Tenant, is made the responsibility of Tenant pursuant to Section 28(a) above. To the extent any such Operating Cost relating to Hazardous Material is subsequently
recovered or reimbursed through insurance, or recovery from responsible third parties or other action, Tenant shall be entitled to a proportionate reimbursement to the extent it has paid its share of such Operating Cost to which such recovery or
reimbursement relates. 

  
 -25-

 (c) It shall not be unreasonable for Landlord to withhold its consent to any proposed
Transfer if (i) the proposed transferee’s anticipated use of the Premises involves the generation, storage, use, treatment, or disposal of Hazardous Material; (ii) the proposed Transferee has been required by any prior landlord,
lender, or governmental authority to take remedial action in connection with Hazardous Material contaminating a property if the contamination resulted from such Transferee’s actions or use of the property in question; or (iii) the proposed
Transferee is subject to an enforcement order issued by any governmental authority in connection with the use, disposal, or storage of a Hazardous Material. 
 (d) As used herein, the term “Hazardous Material” means any hazardous or toxic substance, material, or waste which is or becomes regulated by any local governmental authority, the State
of California or the United States Government. The term “Hazardous Material” includes, without limitation, any material or substance which is (i) defined as “Hazardous Waste,” “Extremely Hazardous Waste,” or
“Restricted Hazardous Waste” under Sections 25115, 25117 or 25122.7, or listed pursuant to Section 25140, of the California Health and Safety Code, Division 20, Chapter 6.5 (Hazardous Waste Control Law),
(ii) defined as a “Hazardous Substance” under Section 25316 of the California Health and Safety Code, Division 20, Chapter 6.8 (Carpenter-Presley-Tanner Hazardous Substance Account Act), (iii) defined as a
“Hazardous Material,” “Hazardous Substance,” or “Hazardous Waste” under Section 25501 of the California Health and Safety Code, Division 20, Chapter 6.95 (Hazardous Materials Release Response Plans and
Inventory), (iv) defined as a “Hazardous Substance” under Section 25281 of the California Health and Safety Code, Division 20, Chapter 6.7 (Underground Storage of Hazardous Substances), (v) petroleum,
(vi) asbestos, (vii) listed under Article 9 or defined as Hazardous or extremely hazardous pursuant to Article 11 of Title 22 of the California Administrative Code, Division 4, Chapter 20, (viii) designated as
a “Hazardous Substance” pursuant to Section 311 of the Federal Water Pollution Control Act (33 U.S.C. § 1317), (ix) defined as a “Hazardous Waste” pursuant to Section 1004 of the Federal Resource
Conservation and Recovery Act, 42 U.S.C. § 6901 et seq. (42 U.S.C. § 6903), or (x) defined as a “Hazardous Substance” pursuant to Section 101 of the Comprehensive Environmental Response, Compensation
and Liability Act, 42 U.S.C. § 9601 et seq. (42 U.S.C. § 9601). 
 (e) As used herein, the term
“Laws” means any applicable federal, state or local law, ordinance, or regulation relating to any Hazardous Material affecting the Project, including, without limitation, the laws, ordinances, and regulations referred to in
Section 28(d) above. 
 ARTICLE 29 
 SURRENDER OF PREMISES; REMOVAL OF PROPERTY 
 (a) The voluntary or
other surrender of this Lease by Tenant to Landlord, or a mutual termination hereof, shall not work a merger, and shall at the option of Landlord, operate as an assignment to it of any or all subleases or subtenancies affecting the Premises.

 (b) Upon the expiration of the Term of this Lease, or upon any earlier termination of this Lease, Tenant shall quit and
surrender possession of the Premises to Landlord in good order and condition, reasonable wear and tear and repairs which are Landlord’s obligation excepted, and shall, without expense to Landlord, remove or cause to be removed from the Premises
all debris and rubbish, all furniture, equipment, business and trade fixtures, free-standing cabinet work, moveable partitioning, telephone and data cabling and other articles of personal property in the Premises except to the extent Landlord elects
by notice to Tenant to exercise its option to have any subleases or subtenancies assigned to it. Tenant shall be responsible for the cost to repair all damage to the Premises resulting from the removal of any of such items from the Premises,
provided that Landlord shall have the right to either (I) cause Tenant to perform said repair work, or (II) perform said repair work itself, at Tenant’s expense (with any such costs incurred by Landlord to be reimbursed by Tenant to
Landlord within three (3) business days following written demand therefor from Landlord). 
 (c) Whenever Landlord shall
reenter the Premises as provided in Article 20 hereof, or as otherwise provided in this Lease, any property of Tenant not removed by Tenant upon the expiration of the Term of this Lease (or within forty-eight (48) hours after a termination
by reason of Tenant’s default), as provided in this Lease, shall be considered abandoned and Landlord may remove any or all of such items and dispose of the same in any manner or store the same in a public warehouse or elsewhere for the account
and at the expense and risk of Tenant, and if Tenant shall fail to pay the cost of storing any such property after it has been 

  
 -26-

 
stored for a period of thirty (30) days or more, Landlord may sell any or all of such property at public or private sale, in such manner and at such times and places as Landlord, in its sole
discretion, may deem proper, without notice to or demand upon Tenant, for the payment of all or any part of such charges or the removal of any such property, and shall apply the proceeds of such sale as follows: first, to the cost and expense of
such sale, including reasonable attorneys’ fees and costs for services rendered; second, to the payment of the cost of or charges for storing any such property; third, to the payment of any other sums of money which may then or thereafter be
due to Landlord from Tenant under any of the terms hereof; and fourth, the balance, if any, to Tenant. 
 (d) All fixtures,
Tenant Improvements, Alterations and/or appurtenances attached to or built into the Premises prior to or during the Term, whether by Landlord or Tenant and whether at the expense of Landlord or Tenant, or of both, shall be and remain part of the
Premises and shall not be removed by Tenant at the end of the Term unless otherwise expressly provided for in this Lease or unless such removal is required by Landlord. Such fixtures, Tenant Improvements, Alterations and/or appurtenances shall
include but not be limited to: all floor coverings, drapes, paneling, built-in cabinetry, molding, doors, vaults (including vault doors), plumbing systems, security systems, electrical systems, lighting systems, communication systems, all fixtures
and outlets for the systems mentioned above and for all telephone, radio and television purposes, and any special flooring or ceiling installations. 
 ARTICLE 30 
 MISCELLANEOUS 

(a) SEVERABILITY; ENTIRE AGREEMENT. ANY PROVISION OF THIS LEASE WHICH SHALL PROVE TO BE INVALID, VOID, OR ILLEGAL SHALL
IN NO WAY AFFECT, IMPAIR OR INVALIDATE ANY OTHER PROVISION HEREOF AND SUCH OTHER PROVISIONS SHALL REMAIN IN FULL FORCE AND EFFECT. THIS LEASE AND THE EXHIBITS AND ANY ADDENDUM ATTACHED HERETO CONSTITUTE THE ENTIRE AGREEMENT BETWEEN THE PARTIES
HERETO WITH REGARD TO TENANT’S OCCUPANCY OR USE OF ALL OR ANY PORTION OF THE PROJECT, AND NO PRIOR AGREEMENT OR UNDERSTANDING PERTAINING TO ANY SUCH MATTER SHALL BE EFFECTIVE FOR ANY PURPOSE. NO PROVISION OF THIS LEASE MAY BE AMENDED OR
SUPPLEMENTED EXCEPT BY AN AGREEMENT IN WRITING SIGNED BY THE PARTIES HERETO OR THEIR SUCCESSOR IN INTEREST. THE PARTIES AGREE THAT ANY DELETION OF LANGUAGE FROM THIS LEASE PRIOR TO ITS MUTUAL EXECUTION BY LANDLORD AND TENANT SHALL NOT BE CONSTRUED
TO HAVE ANY PARTICULAR MEANING OR TO RAISE ANY PRESUMPTION, CANON OF CONSTRUCTION OR IMPLICATION INCLUDING, WITHOUT LIMITATION, ANY IMPLICATION THAT THE PARTIES INTENDED THEREBY TO STATE THE CONVERSE, OBVERSE OR OPPOSITE OF THE DELETED LANGUAGE.

 (b) Attorneys’ Fees; Waiver of Jury Trial. 

(i) In any action to enforce the terms of this Lease, including any suit by Landlord for the recovery of rent or possession of the
Premises, the losing party shall pay the successful party a reasonable sum for attorneys’ fees and costs in such suit and such attorneys’ fees and costs shall be deemed to have accrued prior to the commencement of such action. Tenant shall
also reimburse Landlord for all costs incurred by Landlord in connection with enforcing its rights under this Lease against Tenant following a bankruptcy by Tenant, including, without limitation, legal fees, experts’ fees and expenses and court
costs. 
 (ii) TO THE EXTENT PERMITTED BY LAW, EACH PARTY HEREBY WAIVES ANY RIGHT TO A TRIAL BY JURY IN ANY ACTION
SEEKING SPECIFIC PERFORMANCE OF ANY PROVISION OF THIS LEASE, FOR DAMAGES FOR ANY BREACH UNDER THIS LEASE, OR OTHERWISE FOR ENFORCEMENT OF ANY RIGHT OR REMEDY HEREUNDER. 
 (c) Time of Essence. Each of Tenant’s covenants herein is a condition and time is of the essence with respect to the performance of every provision of this Lease. 

  
 -27-

 (d) Headings; Joint and Several. The article headings contained in this Lease are for
convenience only and do not in any way limit or amplify any term or provision hereof. The terms “Landlord” and “Tenant” as used herein shall include the plural as well as the singular, the neuter shall include the masculine and
feminine genders and the obligations herein imposed upon Tenant shall be joint and several as to each of the persons, firms or corporations of which Tenant may be composed. 
 (e) Reserved Area. Tenant hereby acknowledges and agrees that the exterior walls of the Premises and the area between the finished ceiling of the Premises and the slab of the floor of the Project
thereabove have not been demised hereby and the use thereof together with the right to install, maintain, use, repair and replace pipes, ducts, conduits, wiring and cabling leading through, under or above the Premises or throughout the Project in
locations which will not materially interfere with Tenant’s use of the Premises and serving other parts of the Project are hereby excepted and reserved unto Landlord. 
 (f) NO OPTION. THE SUBMISSION OF THIS LEASE BY LANDLORD, ITS AGENT OR REPRESENTATIVE FOR EXAMINATION OR EXECUTION BY TENANT DOES NOT CONSTITUTE AN OPTION OR OFFER TO LEASE THE PREMISES
UPON THE TERMS AND CONDITIONS CONTAINED HEREIN OR A RESERVATION OF THE PREMISES IN FAVOR OF TENANT, IT BEING INTENDED HEREBY THAT THIS LEASE SHALL ONLY BECOME EFFECTIVE UPON THE EXECUTION HEREOF BY LANDLORD AND TENANT AND DELIVERY OF A FULLY
EXECUTED LEASE TO TENANT. 
 (g) Use of Project Name; Improvements. Tenant shall not be allowed to use the name,
picture or representation of the Project, or words to that effect, in connection with any business carried on in the Premises or otherwise (except as Tenant’s address) without the prior written consent of Landlord. In the event that Landlord
undertakes any additional improvements on the Real Property including but not limited to new construction or renovation or additions to the existing improvements, Landlord shall not be liable to Tenant for any noise, dust, vibration or interference
with access to the Premises or disruption in Tenant’s business caused thereby. 
 (h) Rules and Regulations. Tenant
shall observe faithfully and comply strictly with the rules and regulations (“Rules and Regulations”) attached to this Lease as Exhibit “B” and made a part hereof, and such other Rules and Regulations as Landlord may
from time to time reasonably adopt for the safety, care and cleanliness of the Project, the facilities thereof, or the preservation of good order therein. Landlord shall not be liable to Tenant for violation of any such Rules and Regulations, or for
the breach of any covenant or condition in any lease by any other tenant in the Project. A waiver by Landlord of any Rule or Regulation for any other tenant shall not constitute nor be deemed a waiver of the Rule or Regulation for this Tenant.

 (i) Quiet Possession. Upon Tenant’s paying the Basic Rental, Additional Rent and other sums provided hereunder
and observing and performing all of the covenants, conditions and provisions on Tenant’s part to be observed and performed hereunder, Tenant shall have quiet possession of the Premises for the entire Term hereof, subject to all of the
provisions of this Lease. 
 (j) Rent. All payments required to be made hereunder to Landlord shall be deemed to be rent,
whether or not described as such. 
 (k) Successors and Assigns. Subject to the provisions of Article 15 hereof, all
of the covenants, conditions and provisions of this Lease shall be binding upon and shall inure to the benefit of the parties hereto and their respective heirs, personal representatives, successors and assigns. 

(l) Notices. Any notice required or permitted to be given hereunder shall be in writing and may be given by personal service
evidenced by a signed receipt (or refusal to accept delivery) or sent by registered or certified mail, return receipt requested, or via overnight courier, and shall be effective upon proof of delivery (or refusal to accept delivery), addressed to
Tenant at the Premises or to Landlord at the management office for the Project, with a copy to Landlord, c/o Arden Realty, Inc., 11601 Wilshire Boulevard, Fourth Floor, Los Angeles, California 90025, Attn: Legal Department. Either party may by
notice to the other specify a different address for notice purposes except that, upon Tenant’s taking possession of the Premises, the Premises shall 

  
 -28-

 
constitute Tenant’s address for notice purposes. A copy of all notices to be given to Landlord hereunder shall be concurrently transmitted by Tenant to such party hereafter designated by
notice from Landlord to Tenant. Any notices sent by Landlord regarding or relating to eviction procedures, including without limitation three (3) day notices, may be sent by regular mail. 

(m) Persistent Delinquencies. In the event that Tenant shall be delinquent by more than fifteen (15) days in the payment of
rent on three (3) separate occasions in any twelve (12) month period, Landlord shall have the right to terminate this Lease by thirty (30) days written notice given by Landlord to Tenant within thirty (30) days of the last such
delinquency. 
 (n) Right of Landlord to Perform. All covenants and agreements to be performed by Tenant under any of the
terms of this Lease shall be performed by Tenant at Tenant’s sole cost and expense and without any abatement of rent. If Tenant shall fail to pay any sum of money, other than rent, required to be paid by it hereunder or shall fail to perform
any other act on its part to be performed hereunder, and such failure shall continue beyond any applicable cure period set forth in this Lease, Landlord may, but shall not be obligated to, without waiving or releasing Tenant from any obligations of
Tenant, make any such payment or perform any such other act on Tenant’s part to be made or performed as is in this Lease provided. All sums so paid by Landlord and all reasonable incidental costs, together with interest thereon at the rate
specified in Section 20(e) above from the date of such payment by Landlord, shall be payable to Landlord on demand and Tenant covenants to pay any such sums, and Landlord shall have (in addition to any other right or remedy of Landlord) the
same rights and remedies in the event of the nonpayment thereof by Tenant as in the case of default by Tenant in the payment of the rent. 
 (o) Access, Changes in Project, Facilities, Name. 
 (i) Every part of the
Project except the inside surfaces of all walls, windows and doors bounding the Premises (including exterior building walls, the rooftop, core corridor walls and doors and any core corridor entrance), and any space in or adjacent to the Premises or
within the Project used for shafts, stacks, pipes, conduits, fan rooms, ducts, electric or other utilities, sinks or other building facilities, and the use thereof, as well as access thereto through the Premises for the purposes of operation,
maintenance, decoration and repair, are reserved to Landlord. 
 (ii) Landlord reserves the right, without incurring any
liability to Tenant therefor, to make such changes in or to the Project and the fixtures and equipment thereof, as well as in or to the street entrances, halls, passages, elevators, stairways and other improvements thereof, as it may deem necessary
or desirable. 
 (iii) Landlord may adopt any name for the Project and Landlord reserves the right, from time to time, to change
the name and/or address of the Project at any time. 
 (p) Signing Authority. If Tenant is a corporation, partnership or
limited liability company, each individual executing this Lease on behalf of said entity represents and warrants that he or she is duly authorized to execute and deliver this Lease on behalf of said entity in accordance with: (i) if Tenant is a
corporation, a duly adopted resolution of the Board of Directors of said corporation or in accordance with the By-laws of said corporation, (ii) if Tenant is a partnership, the terms of the partnership agreement, and (iii) if Tenant is a
limited liability company, the terms of its operating agreement, and that this Lease is binding upon said entity in accordance with its terms. Concurrently with Tenant’s execution of this Lease, Tenant shall provide to Landlord a copy of:
(A) if Tenant is a corporation, such resolution of the Board of Directors authorizing the execution of this Lease on behalf of such corporation, which copy of resolution shall be duly certified by the secretary or an assistant secretary of the
corporation to be a true copy of a resolution duly adopted by the Board of Directors of said corporation and shall be in a form reasonably acceptable to Landlord, (B) if Tenant is a partnership, a copy of the provisions of the partnership
agreement granting the requisite authority to each individual executing this Lease on behalf of said partnership, and (C) if Tenant is a limited liability company, a copy of the provisions of its operating agreement granting the requisite
authority to each individual executing this Lease on behalf of said limited liability company. In the event Tenant fails to comply with the requirements set forth in this subparagraph (p), then each individual executing this Lease shall be
personally liable, jointly and severally along with Tenant, for all of Tenant’s obligations in this Lease. 

  
 -29-

 (q) Identification of Tenant. 

(i) If Tenant constitutes more than one person or entity, (A) each of them shall be jointly and severally liable for the keeping,
observing and performing of all of the terms, covenants, conditions and provisions of this Lease to be kept, observed and performed by Tenant, (B) the term “Tenant” as used in this Lease shall mean and include each of them jointly and
severally, and (C) the act of or notice from, or notice or refund to, or the signature of, any one or more of them, with respect to the tenancy of this Lease, including, but not limited to, any renewal, extension, expiration, termination or
modification of this Lease, shall be binding upon each and all of the persons or entities executing this Lease as Tenant with the same force and effect as if each and all of them had so acted or so given or received such notice or refund or so
signed. 
 (ii) If Tenant is a partnership (or is comprised of two or more persons, individually and as co-partners of a
partnership) or if Tenant’s interest in this Lease shall be assigned to a partnership (or to two or more persons, individually and as co-partners of a partnership) pursuant to Article 15 hereof (any such partnership and such persons
hereinafter referred to in this Section 30(q)(ii) as “Partnership Tenant”), the following provisions of this Lease shall apply to such Partnership Tenant: 

(A) The liability of each of the parties comprising Partnership Tenant shall be joint and several. 

(B) Each of the parties comprising Partnership Tenant hereby consents in advance to, and agrees to be bound by, any written instrument
which may hereafter be executed, changing, modifying or discharging this Lease, in whole or in part, or surrendering all or any part of the Premises to the Landlord, and by notices, demands, requests or other communication which may hereafter be
given, by the individual or individuals authorized to execute this Lease on behalf of Partnership Tenant under Subparagraph (p) above. 
 (C) Any bills, statements, notices, demands, requests or other communications given or rendered to Partnership Tenant or to any of the parties comprising Partnership Tenant shall be deemed given or
rendered to Partnership Tenant and to all such parties and shall be binding upon Partnership Tenant and all such parties. 

(D) If Partnership Tenant admits new partners, all of such new partners shall, by their admission to Partnership Tenant, be deemed to
have assumed performance of all of the terms, covenants and conditions of this Lease on Tenant’s part to be observed and performed. 
 (E) Partnership Tenant shall give prompt notice to Landlord of the admission of any such new partners, and, upon demand of Landlord, shall cause each such new partner to execute and deliver to Landlord an
agreement in form satisfactory to Landlord, wherein each such new partner shall assume performance of all of the terms, covenants and conditions of this Lease on Partnership Tenant’s part to be observed and performed (but neither
Landlord’s failure to request any such agreement nor the failure of any such new partner to execute or deliver any such agreement to Landlord shall terminate the provisions of clause (D) of this Section 30(q)(ii) or relieve any such
new partner of its obligations thereunder). 
 (r) Survival of Obligations. Any obligations of Tenant occurring prior to
the expiration or earlier termination of this Lease shall survive such expiration or earlier termination. 
 (s)
Confidentiality. Tenant acknowledges that the content of this Lease and any related documents are confidential information. Tenant shall keep such confidential information strictly confidential and shall not disclose such confidential
information to any person or entity other than Tenant’s financial, legal and space planning consultants and any proposed Transferees. 
 (t) Governing Law. This Lease shall be governed by and construed in accordance with the laws of the State of California. No conflicts of law rules of any state or country (including, without
limitation, California conflicts of law rules) shall be applied to result in the application of any substantive or procedural laws of any state or country other than California. All controversies, claims, actions or causes of action arising between
the parties hereto and/or their respective successors and assigns, shall be brought, heard and adjudicated by the courts of 

  
 -30-

 
the State of California, with venue in the County in which the Project is located. Each of the parties hereto hereby consents to personal jurisdiction by the courts of the State of California in
connection with any such controversy, claim, action or cause of action, and each of the parties hereto consents to service of process by any means authorized by California law and consent to the enforcement of any judgment so obtained in the courts
of the State of California on the same terms and conditions as if such controversy, claim, action or cause of action had been originally heard and adjudicated to a final judgment in such courts. Each of the parties hereto further acknowledges that
the laws and courts of California were freely and voluntarily chosen to govern this Lease and to adjudicate any claims or disputes hereunder. 
 (u) Office of Foreign Assets Control. Tenant certifies to Landlord that (i) Tenant is not entering into this Lease, nor acting, for or on behalf of any person or entity named as a terrorist or
other banned or blocked person or entity pursuant to any law, order, rule or regulation of the United States Treasury Department or the Office of Foreign Assets Control, and (ii) Tenant shall not assign this Lease or sublease to any such person
or entity or anyone acting on behalf of any such person or entity. Landlord shall have the right to conduct all reasonable searches in order to ensure compliance with the foregoing. Tenant hereby agrees to indemnify, defend and hold Landlord and the
Landlord Parties harmless from any and all claims arising from or related to any breach of the foregoing certification. 
 (v)
Financial Statements. Within ten (10) days after Tenant’s receipt of Landlord’s written request, Tenant shall provide Landlord with current financial statements of Tenant and financial statements for the three (3) calendar
or fiscal years (if Tenant’s fiscal year is other than a calendar year) prior to the current financial statement year. Any such statements shall be prepared in accordance with generally accepted accounting principles and, if the normal practice
of Tenant, shall be audited by an independent certified public accountant. Landlord agrees that any financial statements delivered to Landlord under this Article 30(v) shall, unless available in the public domain, constitute confidential
information of Tenant and Landlord agrees that it will not disclose or disseminate any information contained in such financial statements (and Tenant may require Landlord to execute a commercially reasonable confidentiality agreement prior to
delivery), provided Tenant acknowledges and agrees that such financial statements may be disclosed by Landlord to Landlord’s affiliates, attorneys, accountants and/or prospective lenders or purchasers so long as such parties agree to keep such
information confidential. 
 (w) Exhibits. The Exhibits attached hereto are incorporated herein by this reference as if
fully set forth herein. 
 (x) Independent Covenants. This Lease shall be construed as though the covenants herein
between Landlord and Tenant are independent (and not dependent) and Tenant hereby expressly waives the benefit of any statute to the contrary and agrees that if Landlord fails to perform its obligations set forth herein, Tenant shall not be entitled
to make any repairs or perform any acts hereunder at Landlord’s expense or to set off of any of the rent or other amounts owing hereunder against Landlord. 
 (y) Counterparts. This Lease may be executed in counterparts, each of which shall be deemed an original, but such counterparts, when taken together, shall constitute one agreement. 

(z) Non-Discrimination. Tenant herein covenants that Tenant and its heirs, executors, administrators and assigns, and all persons
claiming under or through Tenant, and this Lease is made and accepted upon and subject to the following conditions: 

“That there shall be no discrimination against or segregation of any person or group of persons on account of race, color, creed,
religion, sex, marital status, national origin or ancestry, in the leasing, subleasing, transferring, use, occupancy, tenure or enjoyment of the Premises, nor shall Tenant, or any person claiming under or through Tenant, establish or permit any such
practice or practices of discrimination or segregation with reference to the selection, location, number, use or occupancy of tenants, subtenants or vendees in the Premises.” 

(aa) Roof Equipment. If Tenant desires to use the roof of the Project to install communication equipment or condensers for the
Supplemental Units on the roof of the Project 

  
 -31-

 
to be used from the Premises, Tenant may so notify Landlord in writing (“Roof Equipment Notice”), which Roof Equipment Notice shall generally describe the specifications for the
equipment desired by Tenant. If Tenant delivers a Roof Equipment Notice, then subject to all governmental laws, rules and regulations, Tenant and Tenant’s contractors (which shall first be reasonably approved by Landlord) shall have the right
and access to install, repair, replace, remove, operate and maintain (i) condensers for the Supplemental Units and/or (ii) one (1) so-called “satellite dish” or other similar device, such as antennae (collectively,
“Communication Equipment”) no greater than one (1) meter in diameter, together with aesthetic screening designated by Landlord and all cable, wiring, conduits and related equipment, for the purpose of receiving and sending
radio, television, computer, telephone or other communication signals, at a location on the roof of the Project designated by Landlord. The condensers for the Supplemental Units and the Communication Equipment may be collectively referred to herein
as the “Roof Equipment.” Landlord shall have the right to require Tenant to relocate the Roof Equipment at any time to another location on the roof of the Project reasonably approved by Tenant at Landlord’s expense. Tenant
shall retain Landlord’s designated roofing contractor to make any necessary penetrations and associated repairs to the roof in order to preserve Landlord’s roof warranty. Tenant’s installation and operation of the Roof Equipment shall
be governed by the following terms and conditions: 
 (A) Tenant’s right to install, replace, repair, remove, operate and
maintain the Roof Equipment shall be subject to all governmental laws, rules and regulations and covenants, conditions and restrictions and Landlord makes no representation that such covenants, conditions and restrictions and laws, rules and
regulations permit such installation and operation. 
 (B) All plans and specifications for the Roof Equipment shall be subject
to Landlord’s reasonable approval. 
 (C) All costs of installation, operation and maintenance of the Roof Equipment and
any necessary related equipment (including, without limitation, costs of obtaining any necessary permits and connections to the Project’s electrical system) shall be borne by Tenant. 

(D) It is expressly understood that Landlord retains the right to use the roof of the Project for any purpose whatsoever provided that
Landlord shall not unduly interfere with Tenant’s use of the Roof Equipment. 
 (E) Tenant shall use the Roof Equipment so
as not to cause any interference to other tenants in the Project or with any other tenant’s Communication Equipment or the Project’s heating, ventilation and air condition system, and not to damage the Project or interfere with the normal
operation of the Project. 
 (F) Landlord shall not have any obligations with respect to the Roof Equipment. Landlord makes no
representation that (i) the Communications Equipment will be able to receive or transmit communication signals without interference or disturbance (whether or not by reason of the installation or use of similar equipment by others on the roof
of the Project) or (ii) that the Supplemental Units will be able to adequately heat, ventilate or cool the Premises, and Tenant agrees that Landlord shall not be liable to Tenant therefor. Tenant shall not lease or otherwise make the Roof
Equipment available to any third party and the Roof Equipment shall be only for Tenant’s use in connection with the conduct of Tenant’s business in the Premises. 
 (G) Tenant shall (i) be solely responsible for any damage caused as a result of the Roof Equipment, (ii) promptly pay any tax, license or permit fees charged pursuant to any laws or regulations
in connection with the installation, maintenance or use of the Roof Equipment and comply with all precautions and safeguards recommended by all governmental authorities, and (iii) pay for all necessary repairs, replacements to or maintenance of
the Roof Equipment. 
 (H) The Roof Equipment shall remain the sole property of Tenant. Tenant shall remove the Roof Equipment
and related equipment at Tenant’s sole cost and expense upon the expiration or sooner termination of this Lease or upon the imposition of any governmental law or regulation which may require removal, and shall repair the Project upon such
removal to the extent required by such work of removal. If Tenant fails to remove the Roof 

  
 -32-

 
Equipment and repair the Project within fifteen (15) days after the expiration or earlier termination of this Lease, Landlord may do so at Tenant’s expense. The provisions of this
Section 30(aa)(H) shall survive the expiration or earlier termination of this Lease. 
 (I) The Roof Equipment shall be
deemed to constitute a portion of the Premises for purposes of Articles 13 and 14 of this Lease. 
 (J) Upon request from
Landlord, Tenant agrees to execute a license agreement with Landlord or Landlord’s rooftop management company regarding Tenant’s installation, use and operation of the Roof Equipment, which license agreement shall be in commercially
reasonable form, shall not require any payments from Tenant and shall incorporate the terms and conditions of this Section 30(aa). 
 ARTICLE 31 
 SIGNAGE/DIRECTORY 

Provided Tenant is not in default hereunder, as a charge to the Improvement Allowance (as defined in the Tenant Work Letter attached
hereto as Exhibit “D” and made part hereof), Tenant shall have the right to (i) one (1) line in the lobby directory during the Term and (ii) Project-standard suite entry signage. In addition, provided Tenant is not in
default hereunder, Tenant shall have the right, as a charge to the Improvement Allowance (as defined in the Tenant Work Letter attached hereto as Exhibit “D” and made part hereof), to install (i) a strip on the Project’s
“monument” sign (“Monument Signage”) and (ii) one (1) building-top sign at the top of the Project (“Building-Top Signage”). The Monument Signage and the Building-Top Signage may be collectively
referred to herein as “Tenant’s Signage”. The graphics, materials, size, color, design, lettering, lighting (if any), specifications and exact location of Tenant’s Signage (collectively, the “Signage
Specifications”) shall be subject to the prior written approval of Landlord, which approval shall not be unreasonably withheld. In addition, Tenant’s Signage and all Signage Specifications therefore shall be subject to Tenant’s
receipt of all required governmental permits and approvals, shall be subject to all applicable governmental laws and ordinances, and all covenants, conditions and restrictions affecting the Project. Tenant hereby acknowledges that, notwithstanding
Landlord’s approval of Tenant’s Signage and/or the Signage Specifications therefor, Landlord has made no representations or warranty to Tenant with respect to the probability of obtaining such approvals and permits. In the event Tenant
does not receive the necessary permits and approvals for Tenant’s Signage, Tenant’s and Landlord’s rights and obligations under the remaining provisions of this Lease shall not be affected. The cost of installation of Tenant’s
Signage, as well as all costs of design and construction of Tenant’s Signage and all other costs associated with Tenant’s Signage, including, without limitation, permits, maintenance and repair, shall be the sole responsibility of Tenant.
Notwithstanding anything to the contrary contained herein, in the event that at any time during the Term of this Lease, Tenant fails to occupy at least 15,000 square feet of the Premises, Tenant’s right to the Building-Top Signage shall
thereupon terminate and Tenant shall remove the Building-Top Signage as provided in this Article 31 below. The rights to Tenant’s Signage shall be personal to the originally named Tenant and may not be transferred. Should the Signage require
maintenance or repairs as determined in Landlord’s reasonable judgment, Landlord shall have the right to provide written notice thereof to Tenant and Tenant shall cause such repairs and/or maintenance to be performed within thirty
(30) days after receipt of such notice from Landlord at Tenant’s sole cost and expense. Should Tenant fail to perform such maintenance and repairs within the period described in the immediately preceding sentence, Landlord shall have the
right to cause such work to be performed and to charge Tenant, as Additional Rent, for the cost of such work. Upon the expiration or earlier termination of this Lease (or the termination of Tenant’s Building-Top Signage right as described
above), Tenant shall, at Tenant’s sole cost and expense, cause the Tenant’s Signage to be removed from the monument and the exterior of the Project and shall cause the monument and the exterior of the Project to be restored to the
condition existing prior to the placement of Tenant’s Signage. If Tenant fails to remove Tenant’s Signage and to restore the monument and the exterior of the Project as provided in the immediately preceding sentence within thirty
(30) days following the expiration or earlier termination of this Lease (or the termination of Tenant’s Building-Top Signage as provided above), then Landlord may perform such work, and all costs and expenses incurred by Landlord in so
performing such work shall be reimbursed by Tenant to Landlord within ten (10) days after Tenant’s receipt of invoice therefor. The immediately preceding sentence shall survive the expiration or earlier termination of this Lease.

  
 -33-

 ARTICLE 32 

CONTINGENCY 
 This Lease is subject to and conditional upon Landlord entering into an agreement with New Vista Asset Management, the current tenant of a portion of the Premises, whereby such existing tenant agrees to
terminate its existing lease prior to the scheduled date of expiration thereof upon terms acceptable to Landlord (the “Contingency”). If the Contingency is not satisfied, Landlord shall so notify Tenant, in which case this Lease
shall be null and void, Landlord shall immediately refund the cash security deposit and return the Letter of Credit to Tenant and neither party shall have any further obligation to the other. 

ARTICLE 33 
 OPTION TO EXTEND 
 (a) Option Right. Landlord hereby grants
the Tenant named in this Lease (the “Original Tenant”) one (1) option (“Option”) to extend the Term for the entire Premises for a period of three (3) years (the “Option Term”), which
Option shall be exercisable only by written notice delivered by Tenant to Landlord as set forth below. The rights contained in this Article 33 shall be personal to the Original Tenant and may only be exercised by the Original Tenant (and not
any assignee, sublessee or other transferee of the Original Tenant’s interest in this Lease) if the Original Tenant occupies the entire Premises as of the date of Tenant’s Acceptance (as defined in Section 33(c) below). 

(b) Option Rent. The rent payable by Tenant during the Option Term (“Option Rent”) shall be equal to 100% of the
“Market Rent” (defined below). “Market Rent” shall mean the applicable Monthly Basic Rental, and all escalations, Direct Costs, additional rent and other charges at which tenants, as of the commencement of the Option Term,
are entering into leases for non-sublease office space which is not encumbered by expansion rights and which is comparable in size, location and quality to the Premises in renewal transactions for a term comparable to the Option Term, which
comparable space is located in office buildings comparable to the Project in San Diego, California, taking into consideration free rent, escalations, tenant improvements and brokerage commissions, and also taking into consideration the value of the
existing improvements in the Premises to Tenant, as compared to the value of the existing improvements in such comparable space, with such value to be based upon the age, quality and layout of the improvements and the extent to which the same could
be utilized by Tenant with consideration given to the fact that the improvements existing in the Premises are specifically suitable to Tenant. 
 (c) Exercise of Option. The Option shall be exercised by Tenant only in the following manner: (i) Tenant shall not be in default, and shall not have been in default under this Lease more than
once, on the delivery date of the Interest Notice and Tenant’s Acceptance; (ii) Tenant shall deliver written notice (“Interest Notice”) to Landlord not more than twelve (12) months nor less than nine (9) months
prior to the expiration of the Term, stating that Tenant is interested in exercising the Option; (iii) within fifteen (15) business days of Landlord’s receipt of Tenant’s written notice, Landlord shall deliver notice
(“Option Rent Notice”) to Tenant setting forth the Option Rent; and (iv) if Tenant desires to exercise such Option, Tenant shall provide Landlord written notice within five (5) business days after receipt of the Option
Rent Notice (“Tenant’s Acceptance”). Tenant’s failure to deliver the Interest Notice or Tenant’s Acceptance on or before the dates specified above shall be deemed to constitute Tenant’s election not to exercise
the Option. If Tenant timely and properly exercises its Option, the Term shall be extended for the Option Term upon all of the terms and conditions set forth in this Lease, except that the rent for the Option Term shall be as indicated in the Option
Rent Notice. 

  
 -34-

 IN WITNESS WHEREOF, the parties have executed this Lease, consisting of the foregoing
provisions and Articles, including all exhibits and other attachments referenced therein, as of the date first above written. 
  

											
	“LANDLORD”	 		 	 ARDEN REALTY LIMITED PARTNERSHIP,
 a Maryland limited partnership

				
		 		 	By:	 	ARDEN REALTY, INC.,
		 		 		 	a Maryland corporation
		 		 		 	Its: Sole General Partner
					
		 		 		 	By:	 	 /s/ Scott E. Lyle

		 		 		 		 	Its:	 	 Scott E. Lyle

		 		 		 		 		 	 Chief Operating Officer

			
	“TENANT”	 		 	VITAL THERAPIES, INC.,
		 		 	a Delaware corporation
				
		 		 	By:	 	 /s/ Aron Stern

		 		 	Print Name:	 	 Aron Stern

		 		 	Title:	 	 Chief Financial Officer

				
		 		 	By:	 	 /s/ T. E. Winters

		 		 	Print Name:	 	 T. E. Winters

		 		 	Title:	 	 Chief Executive Officer

  
 -35-

 EXHIBIT “A” 

PREMISES 
  

 
 This Exhibit “A” is provided for informational purposes only and is intended to be only an
approximation of the layout of the Premises and shall not be deemed to constitute any representation by Landlord as to the exact layout or configuration of the Premises. 

  
 EXHIBIT
“A” 
 -1- 

 EXHIBIT “B” 

RULES AND REGULATIONS 
 1. No sign, advertisement or notice shall be displayed, printed or affixed on or to the Premises or to the outside or inside of the Project or so as to be visible from outside the Premises or Project
without Landlord’s prior written consent. Landlord shall have the right to remove any non-approved sign, advertisement or notice, without notice to and at the expense of Tenant, and Landlord shall not be liable in damages for such removal. All
approved signs or lettering on doors and walls shall be printed, painted, affixed or inscribed at the expense of Tenant by Landlord or by a person selected by Landlord and in a manner and style acceptable to Landlord. 

2. Tenant shall not obtain for use on the Premises ice, waxing, cleaning, interior glass polishing, rubbish removal, towel or other
similar services, or accept barbering or bootblackening, or coffee cart services, milk, soft drinks or other like services on the Premises, except from persons authorized by Landlord and at the hours and under regulations fixed by Landlord. No
vending machines or machines of any description shall be installed, maintained or operated upon the Premises without Landlord’s prior written consent. 
 3. The sidewalks, halls, passages, exits, entrances, elevators and stairways shall not be obstructed by Tenant or used for any purpose other than for ingress and egress from Tenant’s Premises. Under
no circumstances is trash to be stored in the corridors. Notice must be given to Landlord for any large deliveries. Furniture, freight and other large or heavy articles, and all other deliveries may be brought into the Project only at times and in
the manner designated by Landlord, and always at Tenant’s sole responsibility and risk. Landlord may impose reasonable charges for use of freight elevators after or before normal business hours. All damage done to the Project by moving or
maintaining such furniture, freight or articles shall be repaired by Landlord at Tenant’s expense. Tenant shall not take or permit to be taken in or out of entrances or passenger elevators of the Project, any item normally taken, or which
Landlord otherwise reasonably requires to be taken, in or out through service doors or on freight elevators. Tenant shall move all supplies, furniture and equipment as soon as received directly to the Premises, and shall move all waste that is at
any time being taken from the Premises directly to the areas designated for disposal. 
 4. Toilet rooms, toilets, urinals, wash
bowls and other apparatus shall not be used for any purpose other than for which they were constructed and no foreign substance of any kind whatsoever shall be thrown therein. 
 5. Tenant shall not overload the floor of the Premises or mark, drive nails, screw or drill into the partitions, ceilings or floor or in any way deface the Premises. Tenant shall not place typed,
handwritten or computer generated signs in the corridors or any other common areas. Should there be a need for signage additional to the Project standard tenant placard, a written request shall be made to Landlord to obtain approval prior to any
installation. All costs for said signage shall be Tenant’s responsibility. 
 6. In no event shall Tenant place a load upon
any floor of the Premises or portion of any such flooring exceeding the floor load per square foot of area for which such floor is designed to carry and which is allowed by law, or any machinery or equipment which shall cause excessive vibration to
the Premises or noticeable vibration to any other part of the Project. Prior to bringing any heavy safes, vaults, large computers or similarly heavy equipment into the Project, Tenant shall inform Landlord in writing of the dimensions and weights
thereof and shall obtain Landlord’s consent thereto. Such consent shall not constitute a representation or warranty by Landlord that the safe, vault or other equipment complies, with regard to distribution of weight and/or vibration, with the
provisions of this Rule 6 nor relieve Tenant from responsibility for the consequences of such noncompliance, and any such safe, vault or other equipment which Landlord determines to constitute a danger of damage to the Project or a nuisance to other
tenants, either alone or in combination with other heavy and/or vibrating objects and equipment, shall be promptly removed by Tenant, at Tenant’s cost, upon Landlord’s written notice of such determination and demand for removal thereof.

  
 EXHIBIT
“B” 
 -1- 

 7. Tenant shall not use or keep in the Premises or Project any kerosene, gasoline or
inflammable, explosive or combustible fluid or material, or use any method of heating or air-conditioning other than that supplied by Landlord. 
 8. Tenant shall not lay linoleum, tile, carpet or other similar floor covering so that the same shall be affixed to the floor of the Premises in any manner except as approved by Landlord. 

9. Tenant shall not install or use any blinds, shades, awnings or screens in connection with any window or door of the Premises and shall
not use any drape or window covering facing any exterior glass surface other than the standard drapes, blinds or other window covering established by Landlord. 
 10. Tenant shall cooperate with Landlord in obtaining maximum effectiveness of the cooling system by closing window coverings when the sun’s rays fall directly on windows of the Premises. Tenant
shall not obstruct, alter, or in any way impair the efficient operation of Landlord’s heating, ventilating and air-conditioning system. Tenant shall not tamper with or change the setting of any thermostats or control valves. Tenant shall
participate in recycling programs undertaken by Landlord as part of Landlord’s sustainability practices including, without limitation, the sorting and separation of its trash and recycling into such categories as required by such sustainability
practices. 
 11. The Premises shall not be used for manufacturing or for the storage of merchandise except as such storage may
be incidental to the permitted use of the Premises. Tenant shall not, without Landlord’s prior written consent, occupy or permit any portion of the Premises to be occupied or used for the manufacture or sale of liquor or tobacco in any form, or
a barber or manicure shop, or as an employment bureau. The Premises shall not be used for lodging or sleeping or for any improper, objectionable or immoral purpose. No auction shall be conducted on the Premises. 

12. Tenant shall not make, or permit to be made, any unseemly or disturbing noises, or disturb or interfere with occupants of Project or
neighboring buildings or premises or those having business with it by the use of any musical instrument, radio, phonographs or unusual noise, or in any other way. 
 13. No bicycles, vehicles or animals of any kind shall be brought into or kept in or about the Premises, and no cooking shall be done or permitted by any tenant in the Premises, except that the
preparation of coffee, tea, hot chocolate and similar items for tenants, their employees and visitors shall be permitted. Notwithstanding the foregoing and if (and only if) bike racks are not provided by Landlord within the common areas of the
Project, then Tenant may store bicycles in the first floor of the Premises only during normal business hours subject to Landlord’s reasonable security and safety requirements. Article 13 of the Lease shall apply to any such entry and storage of
bicycles. No tenant shall cause or permit any unusual or objectionable odors to be produced in or permeate from or throughout the Premises. The foregoing notwithstanding, Tenant shall have the right to use a microwave and to heat microwavable items
typically heated in an office. No hot plates, toasters, toaster ovens or similar open element cooking apparatus shall be permitted in the Premises. 
 14. The sashes, sash doors, skylights, windows and doors that reflect or admit light and air into the halls, passageways or other public places in the Project shall not be covered or obstructed by any
tenant, nor shall any bottles, parcels or other articles be placed on the window sills. All electrical ceiling fixtures hung in the Premises or spaces along the perimeter of the Project must be of a quality, type, design and bulb color approved in
advance by Landlord. 
 15. No additional locks or bolts of any kind shall be placed upon any of the doors or windows by any
tenant, nor shall any changes be made in existing locks or the mechanisms thereof unless Landlord is first notified thereof, gives written approval, and is furnished a key therefor. Each tenant must, upon the termination of his tenancy, give to
Landlord all keys and key cards of stores, offices, or toilets or toilet rooms, either furnished to, or otherwise procured by, such tenant, and in the event of the loss of any keys so furnished, such tenant shall pay Landlord the cost of replacing
the same or of changing the lock or locks opened by such lost key if Landlord shall deem it necessary to make such change. If more than two keys for one lock are 

  
 EXHIBIT
“B” 
 -2- 

 
desired, Landlord will provide them upon payment therefor by Tenant. Tenant shall not key or re-key any locks. All locks shall be keyed by Landlord’s locksmith only. 

16. Landlord shall have the right to prohibit any advertising by any tenant which, in Landlord’s opinion, tends to impair the
reputation of the Project or its desirability as an office building and upon written notice from Landlord any tenant shall refrain from and discontinue such advertising. 
 17. Landlord reserves the right to control access to the Project by all persons after reasonable hours of generally recognized business days and at all hours on Sundays and legal holidays and may at all
times control access to the equipment areas of the Project outside the Premises. Each tenant shall be responsible for all persons for whom it requests after hours access and shall be liable to Landlord for all acts of such persons. Landlord shall
have the right from time to time to establish reasonable rules and charges pertaining to freight elevator usage, including the allocation and reservation of such usage for tenants’ initial move-in to their premises, and final departure
therefrom. Landlord may also establish from time to time reasonable rules and charges for accessing the equipment areas of the Project, including the risers, rooftops and telephone closets. 

18. Any person employed by any tenant to do janitorial work shall, while in the Project and outside of the Premises, be subject to and
under the control and direction of the Office of the Project or its designated representative such as security personnel (but not as an agent or servant of Landlord, and the Tenant shall be responsible for all acts of such persons). 

19. All doors opening on to public corridors shall be kept closed, except when being used for ingress and egress. Tenant shall cooperate
and comply with any reasonable safety or security programs, including fire drills and air raid drills, and the appointment of “fire wardens” developed by Landlord for the Project, or required by law. Before leaving the Premises unattended,
Tenant shall close and securely lock all doors or other means of entry to the Premises and shut off all lights and water faucets in the Premises. 
 20. The requirements of tenants will be attended to only upon application to the management office of the Project. 
 21. Canvassing, soliciting and peddling in the Project are prohibited and each tenant shall cooperate to prevent the same. 
 22. All office equipment of any electrical or mechanical nature shall be placed by tenants in the Premises in settings approved by Landlord, to absorb or prevent any vibration, noise or annoyance.

 23. No air-conditioning unit or other similar apparatus shall be installed or used by any tenant without the prior written
consent of Landlord. Tenant shall pay the cost of all electricity used for air-conditioning in the Premises if such electrical consumption exceeds normal office requirements, regardless of whether additional apparatus is installed pursuant to the
preceding sentence. 
 24. There shall not be used in any space, or in the public halls of the Project, either by any tenant or
others, any hand trucks except those equipped with rubber tires and side guards. 
 25. All electrical
ceiling fixtures hung in offices or spaces along the perimeter of the Project must be fluorescent and/or of a quality, type, design and bulb color approved by Landlord. Tenant shall not permit the consumption in the Premises of more than 2 1/2 watts per net usable square foot in the Premises in respect of office lighting nor shall Tenant permit the consumption in the Premises of more than 1 1/2 watts per net usable square foot of space in the Premises in respect of the power outlets therein, at any one time. In the event that such limits are exceeded, Landlord shall have the right to require
Tenant to remove lighting fixtures and equipment and/or to charge Tenant for the cost of the additional electricity consumed. 
 26. Parking. 
 (a) Subject to Landlord’s reasonable security requirements,
repairs made by Landlord to the Project and Articles 16 and 18 of the Lease, Tenant shall have access to the 

  
 EXHIBIT
“B” 
 -3- 

 
Project parking facility twenty-four (24) hours per day, seven (7) days per week throughout the Term. 
 (b) Automobiles must be parked entirely within the stall lines on the floor. 
 (c)
All directional signs and arrows must be observed. 
 (d) The speed limit shall be 5 miles per hour. 

(e) Parking is prohibited in areas not striped for parking. 
 (f) Access cards or any other device or form of identification supplied by Landlord (or its operator) shall remain the property of Landlord (or its operator). Such parking identification device (if any)
must be displayed as requested and may not be mutilated in any manner. The serial number of the parking identification device may not be obliterated. Devices are not transferable or assignable and any device in the possession of an unauthorized
holder will be void. There will be a replacement charge to the Tenant or person designated by Tenant of $30.00 for loss of any access card. There shall be a security deposit of $30.00 due at issuance for each card key issued to Tenant. 

(g) Tenant may validate visitor parking by such method or methods as the Landlord may approve, at the validation rate from time to time
generally applicable to visitor parking. 
 (h) Landlord (and its operator) may refuse to permit any person who violates the
within rules to park in the Project parking facility, and any violation of the rules shall subject the automobile to removal from the Project parking facility at the parker’s expense. In either of said events, Landlord (or its operator) shall
refund a prorata portion of the current monthly parking rate and the sticker or any other form of identification supplied by Landlord (or its operator) will be returned to Landlord (or its operator). 

(i) Project parking facility managers or attendants are not authorized to make or allow any exceptions to these Rules and Regulations.

 (j) All responsibility for any loss or damage to automobiles or any personal property therein is assumed by the parker.

 (k) Loss or theft of parking identification devices from automobiles must be reported to the Project parking facility manager
immediately, and a lost or stolen report must be filed by the parker at that time. 
 (l) The parking facilities are for the
sole purpose of parking one automobile per space. Washing, waxing, cleaning or servicing of any vehicles by the parker or his agents is prohibited. 
 (m) Landlord (and its operator) reserves the right to refuse the issuance of monthly stickers or other parking identification devices to any Tenant and/or its employees who refuse to comply with the above
Rules and Regulations and all City, State or Federal ordinances, laws or agreements. 
 (n) Tenant agrees to acquaint all
employees with these Rules and Regulations. 
 (o) No vehicle shall be stored in the Project parking facility for a period of
more than one (1) week. 
 27. The Project is a non-smoking Project. Smoking or carrying lighted cigars or cigarettes in
the Premises or the Project, including the elevators in the Project, is prohibited. 
 28. Tenant shall not, without
Landlord’s prior written consent (which consent may be granted or withheld in Landlord’s absolute discretion), allow any employee or agent to carry any type of gun or other firearm in or about any of the Premises or Project. 

  
 EXHIBIT
“B” 
 -4- 

 EXHIBIT “C” 

NOTICE OF TERM DATES 
 AND TENANT’S PROPORTIONATE SHARE 
  

							
	TO:	 	  
	  	DATE:	 	  

		 	  
	  		 	
		 	  
	  		 	

  

									
	RE:	 	Lease
dated                                        
            , 20    , between
                                         
                                       

		 	                           
                                         
          (“Landlord”), and
                                         
                               
		 	                           
                                         
                                        
(“Tenant”), concerning Suite             , located at
		 	                           
                                         
                                         
                                         
                               .          
      

 Ladies and Gentlemen: 
 In accordance with the Lease, Landlord wishes to advise and/or confirm the following: 
 1. That the Premises have been accepted herewith by the Tenant as being substantially complete in accordance with the Lease and that there is no deficiency in construction. 

2. That the Tenant has taken possession of the Premises and acknowledges that under the provisions of the Lease the Term of said Lease
shall commence as of                      for a term of
                     ending on
                    . 
 3. That in accordance with the Lease, Basic Rental commenced to accrue on                     .

 4. If the Commencement Date of the Lease is other than the first day of the month, the first billing will contain a prorata
adjustment. Each billing thereafter shall be for the full amount of the monthly installment as provided for in said Lease. 
 5.
Rent is due and payable in advance on the first day of each and every month during the Term of said Lease. Your rent checks should be made payable to
                     at
                                         
                       . 
 6. The exact number of rentable square feet within the Premises is                     square
feet. 
 7. Tenant’s Proportionate Share, as adjusted based upon the exact number of rentable square feet within the
Premises is             %. 
 AGREED AND ACCEPTED: 

TENANT: 
  

							
	  
	 	,
	a	 	  
	 	
			
	By:	 	  
	 	
		 	Its:	 	  
	 	

 EXHIBIT ONLY 
 ***DO NOT SIGN*** 

  
 EXHIBIT
“C” 
 -1- 

 EXHIBIT “D” 

TENANT WORK LETTER 
 [VITAL THERAPIES, INC.] 
 This Tenant Work Letter shall set forth
the terms and conditions relating to the renovation of the tenant improvements in the Premises. This Tenant Work Letter is essentially organized chronologically and addresses the issues of the renovation of the Premises, in sequence, as such issues
will arise. 
 SECTION 1 
 LANDLORD’S INITIAL CONSTRUCTION IN THE PREMISES 
 Landlord has
constructed, at its sole cost and expense, the base, shell and core (i) of the Premises, and (ii) of the floor of the Project on which the Premises is located (collectively, the “Base, Shell and Core”). Tenant has
inspected and hereby approves the condition of the Premises and Base, Shell and Core, and agrees that, subject to construction of the Improvements, the Premises and the Base, Shell and Core shall be delivered to Tenant in its current
“as-is” condition. The improvements to be initially installed in the Premises shall be designed and constructed pursuant to this Tenant Work Letter. Any costs of initial design and construction of any improvements to the Premises shall be
an “Improvement Allowance Item”, as that term is defined in Section 2.2 of this Tenant Work Letter. 

SECTION 2 
 IMPROVEMENTS 
 2.1 Improvement Allowance. Tenant shall be
entitled to a one-time improvement allowance (the “Improvement Allowance”) in the amount of $477,950.00 (based on $25.00 per rentable square foot of the Premises) for the costs relating to the initial design and construction of
Tenant’s improvements which are permanently affixed to the Premises (the “Improvements”) and the other Improvement Allowance Items described in Section 2.2 below. In no event shall Landlord be obligated to make
disbursements pursuant to this Tenant Work Letter in a total amount which exceeds the Improvement Allowance and in no event shall Tenant be entitled to any credit for any unused portion of the Improvement Allowance not used by Tenant by the date
which is sixty (60) days after the Commencement Date. 
 2.2 Disbursement of the Improvement Allowance. Except as
otherwise set forth in this Tenant Work Letter, the Improvement Allowance shall be disbursed by Landlord (each of which disbursements shall be made pursuant to Landlord’s disbursement process) for costs related to the construction of the
Improvements and for the following items and costs (collectively, the “Improvement Allowance Items”): (i) payment of the fees of the “Architect” and the “Engineers,” as those terms are defined in
Section 3.1 of this Tenant Work Letter, and payment of the fees incurred by, and the cost of documents and materials supplied by, Landlord and Landlord’s consultants in connection with the preparation and review of the “Construction
Drawings,” as that term is defined in Section 3.1 of this Tenant Work Letter; (ii) the cost of permits; (iii) the cost of any changes in the Base, Shell and Core required by the Construction Drawings; (iv) the cost of any
changes to the Construction Drawings or Improvements required by applicable building codes (the “Code”); and (v) the “Landlord Coordination Fee”, as that term is defined in Section 4.3.2 of this Tenant Work
Letter. However, in no event shall more than Three and 00/100 Dollars ($3.00) per usable square foot of the Improvement Allowance be used for the aggregate cost of items described in (i) and (ii) above; any additional amount incurred as a
result of (i) and (ii) above shall be paid for by Tenant as part of the Over-Allowance Amount. 
 2.3 Standard
Improvement Package. Landlord has established specifications (the “Specifications”) for the Project standard components to be used in the construction of the Improvements in the Premises (collectively, the “Standard
Improvement Package”), which Specifications are available upon request. The quality of Improvements shall be equal to or of 

  
 EXHIBIT
“D” 
 -1- 

 greater quality than the quality of the Specifications, provided that Landlord may, at Landlord’s
option, require the Improvements to comply with certain Specifications. 
 SECTION 3 

CONSTRUCTION DRAWINGS 
 3.1 Selection of Architect/Construction Drawings. Landlord shall retain an architect/space planner designated by Landlord (the “Architect”) to prepare the “Construction
Drawings,” as that term is defined in this Section 3.1. Landlord shall also retain the engineering consultants designated by Landlord (the “Engineers”) to prepare all plans and engineering working drawings relating to the
structural, mechanical, electrical, plumbing, HVAC and life safety work of the Tenant Improvements. The plans and drawings to be prepared by Architect and the Engineers hereunder shall be known collectively as the “Construction
Drawings.” All Construction Drawings shall comply with the drawing format and specifications as reasonably determined by Landlord, and shall be subject to Landlord’s reasonable approval. Landlord’s review of the Construction
Drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly,
notwithstanding that any Construction Drawings are reviewed by Landlord or its space planner, architect, engineers and consultants, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord or Landlord’s space
planner, architect, engineers, and consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in the Construction Drawings. 

3.2 Final Space Plan. Tenant and the Architect have prepared the final space plan for Improvements in the Premises (collectively,
the “Final Space Plan”), which Final Space Plan is attached hereto as Schedule 1 and has been approved by Landlord and Tenant. 
 3.3 Final Working Drawings. Based on the Final Space Plan, Landlord shall cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and the
final architectural working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”) and shall submit the same to Landlord for
Landlord’s approval. Upon Landlord’s approval of Final Working Drawings, Landlord shall submit the Final Working Drawings to Tenant for Tenant’s approval, which shall not be unreasonably withheld. Tenant shall approve or disapprove
any draft of Final Working Drawings within three (3) business days after Tenant’s receipt thereof. Tenant’s disapproval of Final Working Drawings shall include the reasonable reasons for Tenant’s disapproval. If Tenant fails to
disapprove any draft of Final Working Drawings by written notice to Landlord within said three (3) business day period, said draft of Final Working Drawings shall be deemed to be approved by Tenant. 

3.4 Permits. The Final Working Drawings shall be approved or deemed approved by Tenant (the “Approved Working
Drawings”) prior to the commencement of the construction of the Improvements. Landlord shall cause the Architect to immediately submit the Approved Working Drawings to the appropriate municipal authorities for all applicable building
permits necessary to allow “Contractor,” as that term is defined in Section 4.1, below, to commence and fully complete the construction of the Improvements (the “Permits”). No changes, modifications or alterations in
the Approved Working Drawings may be made without the prior written consent of Landlord, which consent shall not be unreasonably withheld. 
 3.5 Time Deadlines. Tenant shall use its best efforts and all due diligence to cooperate with the Architect, the Engineers, and Landlord to complete all phases of the Construction Drawings and the
permitting process and to receive the permits, and with Contractor for approval of the “Cost Proposal,” as that term is defined in Section 4.2 of this Tenant Work Letter, as soon as possible after the execution of the Lease, and, in
that regard, shall meet with Landlord on a scheduled basis to be determined by Landlord, to discuss Tenant’s progress in connection with the same. The applicable dates for approval of items, plans and drawings as described in this
Section 3, Section 4 below may be referenced to herein as the “Time Deadlines”. 

  
 EXHIBIT
“D” 
 -2- 

 SECTION 4 

CONSTRUCTION OF THE IMPROVEMENTS 
 4.1 Contractor. The contractor which shall construct the Improvements shall be a contractor designated by Landlord. The contractor selected may be referred to herein as the
“Contractor”. 
 4.2 Cost Proposal. After the Approved Working Drawings are signed by Landlord and
Tenant, Landlord shall provide Tenant with a cost proposal in accordance with the Approved Working Drawings, which cost proposal shall include, as nearly as possible, the cost of all Improvement Allowance Items to be incurred by Tenant in connection
with the construction of the Improvements (the “Cost Proposal”). Tenant shall approve and deliver the Cost Proposal to Landlord within three (3) business days of the receipt of the same, and upon receipt of the same by
Landlord, Landlord shall be released by Tenant to purchase the items set forth in the Cost Proposal and to commence the construction relating to such items. The date by which Tenant must approve and deliver the Cost Proposal to Landlord shall be
known hereafter as the “Cost Proposal Delivery Date.” 
 4.3 Construction of Improvements by Contractor
under the Coordination of Landlord. 
 4.3.1 Over-Allowance Amount. On the Cost Proposal Delivery Date, Tenant shall
deliver to Landlord an amount (the “Over-Allowance Amount”) equal to the difference between (i) the amount of the Cost Proposal and (ii) the amount of the Improvement Allowance (less any portion thereof already disbursed
by Landlord, or in the process of being disbursed by Landlord, on or before the Cost Proposal Delivery Date). The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any then remaining portion of the Improvement
Allowance, and such disbursement shall be pursuant to the same procedure as the Improvement Allowance. In the event that, after the Cost Proposal Delivery Date, any revisions, changes, or substitutions shall be made to the Construction Drawings or
the Improvements, any additional costs which arise in connection with such revisions, changes or substitutions or any other additional costs shall be paid by Tenant to Landlord immediately upon Landlord’s request as an addition to the
Over-Allowance Amount. 
 4.3.2 Landlord’s Retention of Contractor. Landlord shall independently retain Contractor,
on behalf of Tenant, to construct the Improvements in accordance with the Approved Working Drawings and the Cost Proposal and Landlord shall coordinate the construction by Contractor, and Tenant shall pay a construction coordination fee (the
“Landlord Coordination Fee”) to Landlord in an amount equal to the product of (i) five percent (5%) and (ii) an amount equal to the Improvement Allowance plus the Over-Allowance Amount (as such Over-Allowance Amount
may increase pursuant to the terms of this Tenant Work Letter). 
 SECTION 5 

COMPLETION OF THE IMPROVEMENTS 
 5.1 Substantial Completion. For purposes of this Lease, “Substantial Completion” of the Improvements in the Premises shall occur upon the completion of construction of the
Improvements in the Premises pursuant to the Approved Working Drawings, with the exception of any punch list items and any tenant fixtures, work-stations, built-in furniture, or equipment to be installed by Tenant. 

5.2 Delay of the Substantial Completion of the Premises. Except as provided in this Section 5, the Commencement Date and
Tenant’s obligation to pay rent for the Premises shall occur as set forth in the Lease. However, if there shall be a delay or there are delays in the Substantial Completion of the Improvements in the Premises as a result of the following
(collectively, “Tenant Delays”): 
 5.2.1 Tenant’s failure to comply with the Time Deadlines; 

  
 EXHIBIT
“D” 
 -3- 

 5.2.2 Tenant’s failure to timely approve or not approve (stating the reasons therefor)
any matter requiring Tenant’s approval; 
 5.2.3 A breach by Tenant of the terms of this Tenant Work Letter or the Lease;

 5.2.4 Changes in any of the Construction Drawings after disapproval of the same by Landlord or because the same do not comply
with Code or other applicable laws; 
 5.2.5 Tenant’s request for changes in the Approved Working Drawings; 

5.2.6 Tenant’s requirement for materials, components, finishes or improvements which are not available in a commercially reasonable
time given the anticipated date of Substantial Completion of the Improvements in the Premises, and which are different from, and not included in, the Standard Improvement Package; 

5.2.7 Changes to the Base, Shell and Core required by the Approved Working Drawings; or 

5.2.8 Any other acts or omissions of Tenant, or its agents, or employees; 
 then, notwithstanding anything to the contrary set forth in the Lease or this Tenant Work Letter and regardless of the actual date of the Substantial Completion of Improvements in the Premises, the date
of Substantial Completion thereof shall be deemed to be the date that Substantial Completion would have occurred if no Tenant Delay or Delays, as set forth above, had occurred. 
 SECTION 6 
 MISCELLANEOUS 

6.1 Tenant’s Representative. Tenant has designated Aron Stern as its sole representative with respect to the matters set
forth in this Tenant Work Letter, who, until further notice to Landlord, shall have full authority and responsibility to act on behalf of the Tenant as required in this Tenant Work Letter. 

6.2 Landlord’s Representative. Prior to commencement of construction of Improvements, Landlord shall designate a
representative with respect to the matters set forth in this Tenant Work Letter, who, until further notice to Tenant, shall have full authority and responsibility to act on behalf of the Landlord as required in this Tenant Work Letter. 

6.3 Time of the Essence in This Tenant Work Letter. Unless otherwise indicated, all references herein to a “number of
days” shall mean and refer to calendar days. 

  
 EXHIBIT
“D” 
 -4- 

 SCHEDULE 1 

FINAL SPACE PLANS 
  

 

  
 SCHEDULE 1

 -1- 

  
 

 

  
 SCHEDULE 1

 -2- 

 EXHIBIT “E” 

LETTER OF CREDIT 

Arden Realty Limited Partnership 
 c/o General
Electric Capital Corporation 
 14951 Dallas Parkway, Suite #600 
 Dallas, TX 75254 
 ATTN: Letter of Credit Department 

 

	RE:	Irrevocable Letter of Credit No.                      for
U.S. $                     

 Ladies and Gentlemen: 
 We hereby issue our irrevocable Letter of Credit No.
                     in favor of ARDEN REALTY LIMITED PARTNERSHIP, a Maryland limited partnership (“Beneficiary”), for the account
of
                                        ,
a                     . 
 We
undertake to honor from time to time your draft or drafts at sight on us not exceeding in the aggregate              U.S. Dollars (U.S.
$            ). All drafts hereunder must be marked “Drawn under Irrevocable Letter of Credit No.
                , dated             , 20    .” 

Presentation of drafts drawn hereunder may be made at any time on or before the expiration date hereof at our offices located at
                                        .
Presentation on or before noon of any day other than a Saturday, Sunday or other day on which all commercial banks in (city), (state) are authorized or required to be closed (“Banking Day”) shall result in payment to Beneficiary on the
same date. Drafts presented after noon on any Banking Day shall result in payment to Beneficiary on the next Banking Day. We hereby waive any right that we may otherwise have to delay payment to a later date. If the expiration date is not a Banking
Day, drafts presented on the first following Banking Day shall be deemed timely. Any notice of dishonor must be given within the applicable time period set forth above for payment. 
 Partial drawings are permitted, and this Letter of Credit shall, except to the extent reduced thereby, survive any partial drawings. 
 This Letter of Credit is valid through and including                     ,
20    . 
 It is a condition of this Letter of Credit that it shall be automatically renewed for successive terms of
one (1) year from the above-stated or any future expiration date, which shall become effective without amendment unless Beneficiary receives, not less than sixty (60) days before the above-stated or any future expiration date, written
notice from us (in the manner below provided) that we have elected not to renew this Letter of Credit for any such additional term. If Beneficiary receives such notice of non-renewal from us, then Beneficiary may at any time prior to the then
current expiration date hereof present its draft for payment hereunder. 
 Any notice to Beneficiary in connection with this Letter of Credit
shall be in writing and shall be delivered in hand with receipt acknowledged, or by certified mail (return receipt requested), to Arden Realty Limited Partnership, c/o General Electric Capital Corporation, 14951 Dallas Parkway, Suite #600, Dallas,
TX 75254, ATTN: Letter of Credit Department (or to such other address for any such notices which Beneficiary may hereafter specify) in a written notice delivered to the undersigned. 
 We agree that we shall have no duty or right to inquire as to the basis upon which Beneficiary has determined to present to us any draft under this Letter of Credit. We hereby waive any defense based upon
any allegation of fraud. 

  
 EXHIBIT
“E” 
 -1- 

 We shall not be required or entitled to inquire as to the authority of the person signing any draft or other
instrument contemplated hereunder on behalf of Beneficiary, and we shall accept such signature as conclusive evidence of authority. 
 This
Letter of Credit is transferable in its entirety and not in part to any transferee. Upon any such transfer, all references herein to the beneficiary shall be automatically changed to such transferee, and draft(s) may be issued by such transferee
rather than the beneficiary. 
 This irrevocable Letter of Credit is subject to the International Standby Practices 1998 (“ISP98”),
International Chamber of Commerce Publication 590 and, to the extent not inconsistent therewith, the Uniform Commercial Code of the State of
                    . 
 All of the
terms and conditions of this Letter of Credit are contained herein and shall not be altered except by reduction in the amount due to corresponding payments in like amount in compliance with the aforementioned terms. Except as otherwise expressly set
forth herein, there are no conditions to this Letter of Credit. 
  

			
	Very truly yours,
		
	By:	 	  

	Title:	 	  

  
 EXHIBIT
“E” 
 -2-EX-4.2

 Exhibit 4.2 
  

 
 D E LAWAR E NOV. 17, 2004 SEAL BARRACUDA NETWORKS, INC. CORPORATE This certifies that is the record holder of
BN INCORPORATED UNDER THE LAWS OF THE STATE OF DELAWARE FULLY PAID AND NONASSESSABLE SHARES OF COMMON STOCK, $0.001 PAR VALUE, OF Barracuda Networks, Inc. WITNESSDated: CUSIP 068323 10 4 SEE REVERSE FOR CERTAIN DEFINITIONS COUNTERSIGNED AND
REGISTERED: AMERICAN STOCK TRANSFER & TRUST COMPANY, LLC (NEW YORK, NY) TRANSFER AGENT AND REGISTRAR BY: AUTHORIZED SIGNATURE CHIEF EXECUTIVE OFFICER VICE PRESIDENT, GENERAL COUNSEL & SECRETARY 

 

 
 The Corporation shall furnish without charge to each stockholder who so requests a statement of the powers, designations, preferences
and relative, participating, optional or other special rights of each class of stock of the Corporation or series thereof and the qualifications, limitations or restrictions of such preferences and/or rights. Such requests shall be made to the
Corporation’s Secretary at the principal office of the Corporation. laws or regulations: Additional abbreviations may also be used though not in the above list. TEN COM – as tenants in common TEN ENT – as tenants by the entireties JT
TEN – as joint tenants with right of survivorship and not as tenants in common COM PROP – as community property UNIF GIFT MIN ACT – ... Custodian .... (Cust) (Minor) under Uniform Gifts to Minors Act.. (State) UNIF TRF MIN ACT –.
Custodian (until age .) (Cust) .. under Uniform Transfers (Minor) to Minors Act.. (State) FOR VALUE RECEIVED, _ hereby sell(s), assign(s) and transfer(s) unto PLEASE INSERT SOCIAL SECURITY OR OTHER IDENTIFYING NUMBER OF ASSIGNEE shares
attorney-in-fact to transfer the said stock on the books of the within named Corporation with full power of the substitution in the premises. Dated NOTICE: THE SIGNATURE TO THIS ASSIGNMENT MUST CORRESPOND WITH THE NAME AS WRITTEN UPON THE FACE OF
THE CERTIFICATE IN EVERY PARTICULAR, WITHOUT ALTERATION OR ENLARGEMENT OR ANY CHANGE WHATSOEVER. By THE SIGNATURE(S) SHOULD BE GUARANTEED BY AN ELIGIBLE GUARANTOR INSTITUTION, (BANKS, STOCKBROKERS, SAVINGS AND LOAN ASSOCIATIONS AND CREDIT UNIONS
WITH MEMBERSHIP IN AN APPROVED SIGNATURE GUARANTEE MEDALLION PROGRAM), PURSUANT TO S.E.C. RULE 17Ad-15. GUARANTEES BY A NOTARY PUBLIC ARE NOT ACCEPTABLE. SIGNATURE GUARANTEES MUST NOT BE DATED. Signature(s) Guaranteed: (PLEASE PRINT OR TYPEWRITE
NAME AND ADDRESS, INCLUDING ZIP CODE, OF ASSIGNEE) X X

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00222-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00222-of-00352.parquet"}]]