Document:

Exhibit 10.14

 

Tianlun Mingyuan Rural Complex Project

 

Investment Development Agreement 

 

Party A: People’s Government of Shuntian
Town, Dongyuan County, Heyuan City 

 

Party B: Shenzhen Jiana Technology Co.,
Ltd. 

 

 For the purpose of rapidly promoting the construction
of the rural complex in Dengta Basin in Shuntian Town, Dongyuan County, Heyuan City, making full use of the advantages of the ecological
environment, tourism resources and transportation location, and building a rural complex town with national features, Party A and
Party B have reached an agreement on the investment and development of the “Tianlun Mingyuan Rural Complex” in Shuntian
Town through repeated market researches and consultation, and signed the investment and development agreement as follows on the
basis of equality and mutual benefit: 

 

 Article I Overview of project land: the
“Tianlun Mingyuan Rural Complex” (hereinafter referred to as “the Project”) is constructed in two phases. The
land for Phase I is about 1,700 mu, covering: paddy fields on the north, township road #190 on the west, the Chaping group of the
Daping village on the south, Shuntian river on the east, including commercial and residential construction land of 500 mu, lease
collective construction land of 33 mu, land leased from villagers of 667 mu, and ecological forest of 500 mu. For details, please
refer to the attached drawing - land marked with red line. The land for Phase II is about 800 mu, covering: township road #190
on the north, Daping village boundary (township road #190 and Shuntian river interchange) on the west, the land used in the Phase
I on the east, Shuntian river on the south, in which about 500 mu of leased land, and about 300 mu of the village. 

 

Article II Investment
analysis of the project 

 

1. Total project investment:
the total planned investment of the project is about 1,925 million yuan;

 

2. Capital source: 1,925
million yuan of self-owned capital of the enterprise.

 

3. Estimated project
benefits: the average annual income of the project is 339.3 million yuan; the annual cost of 155.6 million yuan; the annual gross
profit of 183.7 million yuan; the annual business tax of 49.9638 million yuan and the annual income tax of 45.925 million yuan;
the annual net profit of 137.775 million yuan. The completion of the project can create 3,000 jobs in the local area, and a total
of other supporting projects can employ about 1,000 people.

 

Article III Project
construction content: 

 

I. The Phase I of
the project covers a total area of 1,700 mu and a construction area of 365,000m2, and comprises: 

 

(I) An eco-agricultural
tourist area. Cover an area of 950 mu and a building area of 4,000m2, including:

 

1. The ecological protection
forest, covering an area of 500 mu, is the national and provincial ecological protection forest, and a walkway, sightseeing pavilion,
cultural landscape, vegetation will be built for tourists’ touring and sightseeing on the basis of protection.

 

     

     

    

 

2. The ecological estate
covers an area of 200 mu, including commercial and residential land of 3 mu, and leased land of 197 mu. Three ecological estates
will be constructed, composed of custom-made planting (trees, orchards, flowers, vegetables, fruits, and grains), breeding (chickens,
and fish) landscape, yacht marina, etc.

 

 3. The ecological farm occupies an area of 250 mu leasing
land, with the tourism ecological agriculture (planting orchards, flowers, vegetables, and grains) and breeding (cattle, chickens,
and fish), and a high negative ion therapy regimen of greenhouses integrated leisure, health care with the precious flower cultivation;
building a fishing platform by the river; providing pollution-free vegetables, grains, fruits and aquatic products, and poultry
ecological food, sightseeing and food picking for the park residents and tourists. 

 

(II) Health care
and preservation resort 

 

1. The construction
land is 500 mu and the construction area is 330,000m2. The multi-storey foreign-style house is constructed with the
volume ratio of 1.0, including: health resort and preservation resort, enabling about 4,900 people for health, vacation and residence.
Cater to retired veteran cadres in Shenzhen and Guangzhou, groups seeking for high-end care, health preservation, holiday in Hong
Kong, Macao and Taiwan and other areas across the country.

 

2. Supporting facilities
for park construction

 

Park roads: the main
road is a one-way asphalt road for battery cars; the auxiliary road is a cobblestone road with non-slip bricks.

 

Park landscape: build
water systems, sculptures, wind and rain corridors, rest pavilions, rockery landscape, theme sketches, seats, sculptures and so
on.

 

Park greening: focus
on the nature with grassland, shrubs, trees and so on, forming an interrelated green system combined with a point, line, and the
surface.

 

(III) Cultural and
sports tourism areas 

 

1. Culture and sports
theme park: occupy an area of 70 mu leasing land, and build cultural sculpture groups, personal sculpture memorial hall, biography
gallery, pet park, Fushou cultural park, angling garden, song and dance cultural square, fitness path, children’s paradise, etc.;

 

2. Cultural and sports
center: cover an area of 5 mu and a building area of 3,000m2, including:

 

Art center: art
center, publishing house, tourism company, film and television center, etc.

 

Club: internet
cafe, chess and card room, library, newspaper room, chat room, tea house and so on.

 

College for the aged:
multi-functional hall, small and medium-sized conference room, classroom, and others offering vocal music classes, dance classes,
instrumental music classes, calligraphy classes, art classes, manual art classes, literary creation classes, internet application
classes, health food classes, sports fitness classes and so on; special lectures and various refresher courses will be held.

 

Playground: gymnasium,
table tennis hall, badminton hall, fitness hall, softball hall, swimming pool, gate ball court, tennis court, golf driving range
and so on.

 

Vocational college
of nursing: (additional construction of school premises)

 

    2

     

    

 

3. Art town: its
floor area is 10 mu and building area is 6,500m2; it comprises cultural palace (street), calligraphy and painting village
(street), personal art street, art exhibition hall, art trading hall (museum) engaged in the development of art auction transactions,
online trading, treasure identification, Taobao, etc. A trading “supermarket” will be built with the antique, porcelain,
antique furniture, antique items, and the four treasures of the study, ancient books and paintings, folk handicrafts. Meanwhile,
cross-stitch, paper-cut art, weaving art, folk art processing, exhibition and marketing services will be provided in the center.
Twenty retired painters and calligraphers will be invited to live in the art town on a permanent or temporary basis.

 

 (IV) New service function zone: it
covers an area of 165 mu and a building area of 16,500m2, including 15 mu for collective construction, 15,000m2
for construction, 150 mu for lease and 1,500m2 for construction. 

 

1. Medical center:
the construction area is 5,000m2, the center is made up of:

 

Hospital: it
shall be included in the fixed-point scope of urban basic medical insurance. Establish out-patient department, emergency department,
inpatient department and physical examination center of traditional Chinese medicine and western medicine, and cooperate with famous
hospitals in Guangdong to develop remote consultation system, 24-hour visual monitoring system and automatic voice recognition
call system for the elderly;

 

Health care center:
provide graded care and rehabilitation, psychological counseling and psychological status assessment, and health care and nursing
services.

 

 Hospice care center: build
the center according to the national design standards of hospice care hospitals, so that the elderly finish the final journey of
life serenely. 

 

2. Health center:
the construction area is 5,000m2, and the construction includes:

 

Institute (Center)
of life sources: the human gene collection bank, umbilical cord blood collection bank, human stem cell collection bank and
some experimental laboratories will be constructed.

 

Zhonghua Dayitang
(health care center): build health care center, health consultation center, health lecture hall, etc.; organize experts and
famous doctors to take turns to sit in the big medical hall and carry out telemedicine; conduct lectures on health care and organize
training activities on health and health care.

 

International health
examination center: the project introduces medical equipment, technology and personnel from the Swiss Health Center of the
Fetuin and Japan’s International Health Examination Center to build a world-class health care center.

 

Health care center:
in the health care center (SPA, spa, fog therapy, magnetic therapy, mineral therapy, mud therapy, fitness and slimming, etc.),
the first-class private and ergonomic health environment in the world will be created.

 

3. Living security
zone: the construction area is 4,000m2, with the living service facilities such as a shopping center, nutrition
catering center, service center (restaurant, bank, hairdressing, laundry, small hotel) and the office space of the center management
personnel.

 

4. Financial service
center: the a building area is 1,000m2, an bank for the aged will be set up to popularize pension mortgage models;
a joint-stock company and a communication center, etc., for the aged, will be established. The just retired elders will enjoy the
opportunities to invest and manage their finances, give full play to their remaining enthusiasm and make achievements in their
old age, and more financial services will be provided for the elderly.

 

    3

     

    

 

5. Heliport: covering
an area of 100 mu and a building area of 500m2, a small heliport with a capacity of 25 helicopters will be built. Not
only will the helicopter parking, repairing, and maintenance services be provided for residential owners, but also transportation,
first aid and other services will be offered to hotel and clubhouse customers, and elderly customers .

 

6. Golf driving range:
covering an area of 50 mu and a building area of 500m2, the golf driving range will be built.

 

II. The Phase II
of the project covers a total area of 800 mu and is planned to be extended on the basis of the Phase I construction. 

 

 Article IV Operation mode 

 

1. Project setup:
When Party B submits the application for project setup, Party A shall be responsible for organizing and coordinating the relevant
departments in Dongyuan County, Heyuan City to handle the matters such as the project site selection, project setup and land index
approval;

 

2. Project design:
Party B shall be responsible for overall conceptual planning and design, architectural and landscape design, tourism planning
and design, and architectural design, and implement the construction after obtaining the consent of Party A and approval of the
planning and construction department of Heyuan Government;

 

3. Land for the project:

 

1 Party A shall
be responsible for completing the land requisition and lease for Party B at the actual standard price, applying for the land index
to the higher authorities concerned, and ensuring the normal development of the project of Party B within the time planned by both
parties;

 

2 In order to
push the project forward quickly, Party A adjusts the commercial and residential construction land of about 200 mu of the existing
land index to be used by Party B within the red line of Party B’s site selection, and Party B shall pay Party A the land expenses
according to the actual land cost.

 

4. Project construction:

 

1 Party A completes:
the project site selection, project setup, land transfer and lease, and Party B will make every effort to organize the investment
and construction of the project.

 

2 Party A shall,
according to the planning and construction of the Tianlun Mingyuan rural complex, coordinate all preferential policies and convenient
channels for handling formalities granted to Party B by the relevant county and city authorities.

 

3 Party B will
create a “Rural Complex” themed community featuring culture, tourism, health preservation, health care and health with
the concept of the characteristic town by constructing the Tianlun Mingyuan rural complex.

 

Article V Cooperation
agreement 

 

1. Party A shall undertake
to complete the project site selection, project approval, land lease and the first batch of commercial and residential construction
land for Party B within 60 days.

 

    4

     

    

 

2. Party B shall immediately
start the conceptual planning and design of the project, the architectural scheme design and the design of construction drawings
after Party A completes the project site selection and project setup, commence the construction within 3 months upon the government’s
approval, and complete the first batch of Phase I construction within three years. Otherwise, Party A shall have the right to recover
the land.

 

 3. Party A shall complete the land requisition within
60 days from the date of submission of the plan book in the scope of the construction land planned and designed in accordance with
the project concept, and the land requisition shall be undertaken by Party A in the form of 58,000 yuan per mu. Party B shall advance
20% of the land requisition payment to Party A before the requisition starts, and make all the requisition payment within 3 days
after the requisition is completed and handed over to Party B. 

 

4. Party B shall make
timely payment according to the time of party A’s land lease, requisition and listing.

 

5. The construction
land provided by Party A shall be used legally, with complete procedures and shall be sold by listing with planning and construction
scheme to ensure the integrity and uniformity of the project.

 

6. Party A shall be
responsible for completing the construction of five supplies and one leveling (links to surface water, underground water, electricity,
road and communication and site levelling) and the pipe system before the land is supplied to Party B.

 

 Article VI Favorable terms 

 

1. Party A shall exempt
and waive the fees and administrative fees (except the fees charged by the third party involved) within the rights of the town,
county and city for the project developed and constructed by Party B;

 

2. Tax relief shall
be given to agricultural, cultural, tourism and pension projects in accordance with relevant provisions.

 

Article VII Liability
for breach of contract 

 

1. After this Agreement
comes into effect, each party shall perform its obligations and agreements in a comprehensive, appropriate and timely manner in
accordance with the provisions of this Agreement and all annexes hereto. Any breach of this Agreement by one party shall constitute
a breach of this Agreement;

 

2. One party breaching
the contract shall compensate the other party for all the losses caused by the breach, and the agreement shall continue to be implemented;

 

3. Failure or delay
of exercising certain right under this Agreement or legally specified shall not constitute a waiver of such right or any other
rights. Separate or partial exercising of certain right under this Agreement or legally specified shall not interfere with the
further continuous exercising of such right or any other rights.

 

Article VIII Modification,
alteration and cancellation of the agreement 

 

1. Any annex to this
Agreement and its appendices shall come into force only after a written agreement is signed by Party A and Party B;

 

2. The Intent Agreement
may also be terminated in advance if the Agreement is unable to be performed due to force majeure, or if the execution of the Agreement
is postponed or the cooperation is terminated through consultation between both parties.

 

    5

     

    

 

Article IX Dispute
resolution 

 

1. The validity, interpretation
and performance of this agreement shall be governed by the laws of the People’s Republic of China;

 

2. Any dispute arising
from this Agreement between the parties hereto shall be settled through friendly consultation. If no settlement can be reached,
the dispute may be submitted to the law arbitration institute for arbitration;

 

3. During the arbitration
under this Article, this Agreement shall remain in full force in all aspects except for the part under arbitration. Apart from
the obligations involved in the arbitration, all parties shall continue to fulfill respective obligations and exercise respective
rights under this Agreement.

 

 Article X Effectiveness of the Agreement 

 

1. The Agreement shall
enter into force after being duly signed by both parties, and shall remain in force from the date of signing to the date of normal
operation after the completion of the Project;

 

2. The Agreement shall
become a document with legal force after it is signed by all parties, and both parties shall strictly abide by it, and no party
shall terminate it without authorization;

 

Article XI Miscellaneous

 

1. Party A shall arrange
relevant departments to cooperate with Party B in the project of Shuntian Business Card, which involves integration, promotion
and publicity;

 

2. For matters not covered
in the Agreement, both parties may sign a supplementary agreement through consultation, and the supplementary agreement shall have
the same legal effect as this Agreement;

 

 3. The Agreement shall be made in quadruplicate, two
for each party. 

 

(No text blow)

 

  

6Exhibit 10.15

 

 

 

 

 

 

 

 

 

 

 

Construction Contract for Construction Project

 

(GF-1999-0201)

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

 

Prepared by the State Administration for Industry
and Commerce, Ministry of Construction of the People’s Republic of China

 

     

     

    

 

Construction Contract for Construction
Project 

 

Part IAgreement 

 

Employer (full name):
Shenzhen Jiana Technology Co., Ltd. (hereinafter referred to as Party A) 

 

Contractor (full name):
Jiangsu Nantong Sanjian Holdings (Group) Co., Ltd (hereinafter referred to as Party B) 

 

In accordance with the
Contract Law of the People’s Republic of China, the Construction Law of the People’s Republic of China, the Property
Law of the People’s Republic of China and other relevant laws and regulations, and in compliance with the principles of equality,
voluntariness, justice and good faith, both parties negotiate an agreement on the construction matters of this construction project
and formulate this contract.

 

I. Project Overview

 

Project name: Hakka
Business Street of Immigrant Culture Plaza 

 

Project location: Shuntian
Town, Dongyuan County, Heyuan City, Guangdong Province 

 

Project content: The
construction area of the project is about 60,000m2, including civil engineering, indoor installation project, decoration
works, landscape greening, road and pipe system of residential area and ancillary supporting project. 

 

Structure type: frame
structure (three storeys) 

 

Complex project shall
be attached with the schedule of the projects contracted by the contractor (Annex 1)

 

Project approval number:

 

Capital source: self-raising

 

II. Contracting scope
and mode of the project 

 

Contracting scope: general
contracting construction within the scope of project design and construction drawings. including Civil engineering and indoor installation
project, decoration works, landscape greening, road and pipe system of residential area and ancillary supporting project such as
fire control, lightning protection, piped gas, termite control, elevator, intelligent installation, electromechanical installation
and outdoor water and electricity installation. 

 

Contracting method:
the project shall be contracted by Party B for general construction with labor and materials, qualified quality, safe construction,
construction period and civilized construction. 

 

    2

     

    

 

III. Contract schedule

 

The contract period
will be 180 days, and the commencement date shall be calculated from the day after Party A issues the commencement notice.

 

IV. Quality standard

 

Project quality standard:
qualified 

 

V. Contract price

 

Amount (in words): provisional
SAY RMB SEVENTY MILLION YUAN OMLY 

 

¥:
70,000,000 yuan (settled according to the agreement) 

 

VI. Contractual documents

 

Documents constituting
the contract include:

 

1. Contract agreement

 

2. Notice of winning
bid

 

3. Tender and its annexes

 

4. Special terms of
this contract

 

5. General terms of
this contract

 

6. Standards, specifications
and relevant technical documents

 

7. Drawings

 

8. Bill of quantities

 

9. Project quotation
or budget statement

 

Any written agreement
or document concerning the discussion of and changes to the project concluded between both parties shall be regarded as an integral
part of this contract.

 

VII.The
interpretation of relevant terms in the Agreement shall be the same as those respectively defined in the General Terms in
Part II of this Contract. 

 

VIII. The Contractor
promises to carry out and complete all construction works for the Employer in accordance with the contract agreement hereunder,
and will undertake the responsibility of project quality warranty within the quality warranty period. 

 

IX. The Employer
shall make commitments to the Contractor to pay the contract prices and other payables in compliance with the time limit and manner
agreed in this Contract. 

 

    3

     

    

 

X. Execution of the
contract 

 

Signing date: December
28, 2017 

 

Signing place: Guangzhou
City, Guangdong Province 

 

The parties hereto agree
that: this Contract shall be concluded when the legal representatives or entrusted agents of both parties signed and affixed with
the official seal of both parties or the special seal for contract. After the project is completed and delivered to Party A for
use, settlement and payment by Party A (excluding warranty fund), the other clauses shall be terminated except that the relevant
warranty clauses are still in force, and the relevant warranty clauses shall be terminated upon the expiration of the warranty
period.

 

 

 

    4

     

    

 

Part IIISpecial Terms 

 

I. Definitions of terms and contract
documents 

 

2. Contract documents
and explanation sequence

 

Contract documents composition
and interpretation sequence: the documents are composed of the Contract Agreement, Notice of Winning Bid, Tender and its annexes,
special terms of the Contract, general terms of Contract, construction drawings, standards, specifications and relevant technical
documents, bill of quantities and project quotation. The sequence of interpretation shall be in accordance with the General
Terms. 

 

3. Language, applicable
laws, standards and specifications

 

3.1 Except for Chinese,
the contract also uses / (language).

 

3.2 Applicable laws
and regulations

 

Laws and administrative
regulations needed to be expressed: The laws and regulations of the state, the department rules of the province and the city,
and the local regulations. 

 

3.3 Applicable standards
and specifications

 

Name of applicable standards
and specifications: It shall be implemented in accordance with the Code for Construction and Acceptance of Building Installation
Projects, the Compulsory Provisions of Engineering Construction Standards and the technical operation specifications
and standards for construction and safety projects in Guangdong Province. 

 

Time of standards and
specifications provided by the Employer:           /           

 

Agreement when there
is no corresponding domestic standard and specification: it shall be implemented according to the standards jointly agreed by
Party A, Party B and the Supervisor. 

 

4. Drawings

 

4.1 The Employer provides
the Contractor with dates and number of sets of drawings: the Employer shall provide the Contractor with eight sets of complete
construction drawings before the project starts 

 

Employer’s confidentiality
requirements on the drawings: internal only 

 

Requirements and costs
on using of foreign drawings:           /           

 

II. General rights and obligations of
both parties 

 

1. Obligations and responsibilities
of Party A:

 

1.1 Party A shall cooperate
to complete the following work by the appointed time and requirement:

 

(1) Party A shall provide
temporary facilities, sites and connections for domestic water, electricity and construction electricity within 100 meters of the
site.

 

    5

     

    

 

(2) The construction
site shall meet the requirements of “three supplies and one leveling” (links to the water, electricity and road and site
levelling) for commencement of construction.

 

(3) The delivery and
acceptance requirements of benchmark and coordinate control point: comply with construction requirements.

 

(4) Party A shall have
the right to supervise the specific implementation methods of Party B; Party B shall report the contact information of the site
project manager to the site representative of Party A during the construction period.

 

(5) Other work to be
done by Party A agreed by both parties: if any quality problem is found, Party A may immediately require Party B to rectify it;
Party A shall be responsible for timely payment of the project delay and expenses; Party A shall pay the project payment according
to the provisions of the Contract. If the project payment is not paid due to Party A’s reasons, Party A shall bear the relevant
expenses.

 

1.2 Work entrusted by
Party A to Party B: subject to the actual situation of construction.

 

2. Obligations and responsibilities
of Party B:

 

2.1 Party B shall complete
the following work by the appointed time and requirement:

 

(1) Party B shall undertake
the security work of construction and responsibility and requirement on construction lighting: Party B shall be responsible for
and bear the necessary expenses. And shall purchase labor safety insurance and pay labor security deposit for the construction
personnel, which shall be implemented in accordance with the provisions of the State.

 

(2) Requirements for
office premises and facilities provided to the supervision company: Party B shall provide 1 office space with water and electricity
and 3 sets of desk and chair office facilities free of charge, and bear the water and electricity costs.

 

(3) Party B shall prepare
the construction organization plan and submit it to Party A for approval, and organize the construction on site according to this
plan.

 

(4) Party B shall provide
its own generators to ensure the continuous construction, and the power generation cost shall be calculated according to the relevant
power generation shift standards of the quota (the power generation equipment shift must be certified before settlement).

 

5. Engineers assigned
by supervision units 

 

Name: ___________ Position:
General Supervision Engineer 

 

5.1 Functional authorities
entrusted by the Employer: control the quality, progress and safety of the construction phase of the project, and organize and
coordinate the work on site. 

 

5.2 Functions and powers
executed after obtaining approval of the Employer: 1. Workload of design change and certification increase or decrease; 2. Commence
order, cease work order and back-to-work order; 

 

    6

     

    

 

6. Engineer dispatched
by the Employer 

 

Name: ___________ Position:
project manager 

 

Functions and powers: control
over project quality, duration and investment.

 

6.1 Engineers’ functions
and powers without supervision rights:           /           

 

7. Project manager

 

Name: Zhao Hui Position:
Project manager 

 

8. Works of the Employer

 

8.1 The Employer shall
complete the following work by the appointed time and requirement:

 

(1) Requirements and
the completion time for the construction site that possesses construction conditions:

 

(2) The time, location and supply
requirements of connecting the construction required water, electricity, telecommunication lines to the construction site: the
water and electricity supply must be connected within 50 meters of the central point of the proposed building and meet the needs
during the construction period before MM/DD, 2017. 

 

(3) The opening time
and requirements of the channel between construction site and public road: the road will be connected to the construction site
and will be unblocked during the construction period by MM/DD, 2017. 

 

(4) The supplying time
of project geology and underground pipelines material: the Employer shall provide Contractor with the foundation and project
underground pipelines of the construction site prior to MM/DD, 2017, and be responsible for the authenticity of the information.

 

(5) The certificate,
the name of the approval document and the time of completion of the construction handled by the Employer: handle the construction
permit and other certificates, approvals and temporary land, water and power for construction that may cut off the road traffic
and damage roads, electrical, communications and other public facilities The formalities for approval of the application as prescribed
by laws and regulations. 

 

(6) The delivery and
acceptance requirements of benchmark and coordinate control point: submit it in writing to the Contractor for on-site inspection.

 

(7) The disclosing time
for drawings reviewing and design: 3 days before commencement 

 

(8) Assist in disposing
protection work of underground pipelines and neighboring buildings, structures (including cultural relic protection buildings)
and old tree and famous wood species surrounding the construction site: the Employer shall coordinate the settlement and bear
all the economic expenses during the period. 

 

(9) Other work to be
done by the Employer agreed by both parties:            /            

 

8.2 Work entrusted by
the Employer to the Contractor:            /            

 

    7

     

    

 

9. Works of the Contractor

 

9.1 The Contractor shall
complete the following work by the appointed time and requirement:

 

(1) Submission time of
design document completed by the Contractor allowed by rating of design qualification and scope of business:           
/           

 

(2) Provide name and
completion time of plan and statement:

 

on the 25th day of
each month, the Employer and the Supervisor shall be provided with the completed project quantity report (including the project
quantity change and the certified budget) and the construction progress plan and material purchase plan for the following month.

 

(3) Party B shall undertake
the security work of construction and responsibility and requirement on daytime construction lighting: based on project demand,
the Contractor shall provide and repair lighting and fencing facilities in construction and take charge of their security; 

 

(4) Requirements on
office and living building and facility provided to the Employer: three rooms 

 

(5) Procedures of transportation,
environmental sanitation and construction noise management in construction site needed to be transacted by the Contractor: observe
the provisions of relevant departments on the construction site, traffic, construction noise, environmental protection and production
safety, and handle the relevant formalities according to the relevant provisions, and notify the Employer in writing. 

 

(6) Special requirements
and costs for the protection of the completed project’s finished products: the Employer shall not bear any expenses for the
protection of finished products constructed by the Contractor. For the construction of the project subcontracted by the Employer
alone, the Contractor shall calculate the protection fee for finished products at 1% of the cost. 

 

(7) Protection requirements
and fee bearing of underground pipelines and neighboring buildings, structures (including cultural relic protection buildings)
and old tree and famous wood species surrounding the construction site: the cost shall be borne by the Employer in accordance
with the general terms, 

 

(8) Requirements on
construction site cleaning: ensure that the construction site is clean and in accordance with the relevant provisions of environmental
sanitation management. 

 

(9) Other work to be
done by the Contractor agreed by both parties:            /            

 

III. Construction
organization design and construction period 

 

10. Progress plan

 

10.1 The time of construction
organization design (construction scheme) and progress plan provided by the Contractor: within 10 days of commencement. 

 

The time confirmed by
the engineers: within 7 days upon receiving the Contractor’s construction organization design and progress plan. 

 

10.2 Requirements related
to the progress plan in the complex project:            /            

 

    8

     

    

 

13. Construction delay

 

13.1 Other circumstances
of construction period postponing agreed by both parties: In case of shutdown due to the Employer’s failure to provide the conditions
for commencement of work as required, ordered by the competent department as a result of the Employer’s failure to handle relevant
formalities, design change of project quantity, power failure of more than eight hours accumulatively in a week, the force majeure
and other non-contractor reasons, the construction period shall be postponed accordingly, which shall be approved by the Supervisor
and the on-site representative of Party A. 

 

IV. Quality and acceptance

 

14. Quality standard

 

1. Strictly check the
work and construction scope of Party B, protect the finished products, avoid cross-contamination, clean and wipe the working face
in time. Ensure that the finished products are not damaged or cross-contaminated due to Party B’s reasons, or it will be taken
as the non-conforming project.

 

2. Strictly comply with
the construction drawings and related specifications and standards, and ensure that the quality of the project must meet the national
construction quality acceptance standards or above.

 

3. According to the
requirements of Party A, Party B shall first construct a local project, which shall be regarded as the quality acceptance and pricing
standards of the project. After reaching the written approval of Party A, the local project shall be regarded as the quality model
standard for acceptance of Party B’s project quality.

 

15. Acceptance 

 

1. It is implemented
according to the acceptance standard of qualified project.

 

2. Concealed works and
intermediate acceptance

 

2.1 Intermediate acceptance
part: all sub-projects and processes, as well as all concealed works, waterproofing projects, facilities and equipment, shall be
subject to intermediate acceptance in accordance with relevant industry regulations.

 

2.2 If it is necessary
to conduct the concealed work and the intermediate acceptance of the project, Party B shall first conduct self-inspection, and
then notify the supervision engineer in writing of the acceptance. The notice shall specify the contents, time and place of concealment
and intermediate acceptance. Where Party B prepares the acceptance record and the acceptance is qualified, the engineer shall sign
the acceptance record for confirmation, and Party B may carry out concealed works and continue construction after signing, confirmation
and consent. Party B shall unconditionally peel off or open holes in the hidden project if the chief engineer of Party A and the
supervision engineer of Party A, whether participating in the acceptance or not, have objection to the concealed work and require
re-inspection. When the project is qualified after inspection, the proposer shall bear all the expenses and the construction period
shall be postponed; however, if the project is found unacceptable, Party B shall assume all the expense incurred thereby without
changing the construction progress.

 

    9

     

    

 

V. Safe and civilized
construction 

 

Conform to the standard
for safe and civilized construction site in the Guangdong Province. 

 

VI. Contract price
and payment 

 

23. Contract price
and adjustment 

 

23.1 The contract price
is tentatively about 70 million yuan (settled according to the actual cost).

 

(1) Adopt the fixed
contract price. The risk scope included in contract price: / 

 

2There are
no problems left over from the contracted project;

 

3The terms
of the construction project design and construction contract are fully performed;

 

4Party B has
fully implemented the terms promised in the Contract.

 

2.2 The following
information shall be provided in the completion settlement:

 

1Written statement
document in triplicate and one electronic document thereof (including project quantity calculation document);

 

2Design change
notice and project contact list;

 

3Valid project
certified list;

 

4Certificate
of acceptance upon completion of the project;

 

5Other valid
documents related to project settlement.

 

6Relevant
construction plan and construction organization design of Party B shall not be used as the basis for settlement, but only as the
technical guidance materials for Party B to complete the project, but the total construction period shall be the basis for settlement
appraisal.

 

2.3 The completion
statement shall be prepared in accordance with the following requirements: it shall comply with the settlement regulations.

 

X. Default, claim
and dispute 

 

35. Liability for breach
of contract

 

1. After this Agreement
comes into effect, Party A shall have the right to terminate this Contract after consultation between both parties if Party B is
unable to complete the project construction as agreed in this Contract (Agreement), and in such case Party B shall leave the site
unconditionally and compensate Party A for its losses.

 

2. Party B shall sign
for the completion of the project (within days) and submit it to Party A for pre-sale upon acceptance, and shall be liable for
the breach of contract and compensate Party A for the loss of sales by Ten thousand yuan only per day for every delay of Party
A’s pre-sale. The maximum fine shall not exceed 3% of the contract amount.

 

    10

     

    

 

3. When Party B completes
the project construction as agreed, Party A’s failure to allocate the project payment as agreed herein shall be deemed as breach
of contract. Party A shall pay the default penalty at 5% of the actual project payment owed to Party B every month until the project
payment is paid off.

 

4. If either party fails
to perform the duties as agreed in the contract, the defaulting party shall compensate the other party for all the economic losses
incurred. In case of shutdown due to Party A, Party A shall assume all economic losses arising therefrom. In case of shutdown due
to Party B, Party B shall assume all economic losses arising therefrom.

 

36. Claim

 

36.1 Both parties agree
to be subject to the general terms of the contract in respect of claim.

 

37. Dispute

 

37.1 Both parties agree
that, if the disputes occur in the process of implementing contract:

 

(1) Both parties shall
settle the matter through friendly negotiation. In case the negotiation fails, either party may file a lawsuit to the People’s
Court of the place where Party B is located.

 

XI. Project Construction
and Relevant Provisions 

 

1. According to the
drawings and requirements provided by Party A, Party B shall be responsible for the organization, construction production and management,
production safety and civilized construction of the whole project construction personnel according to the construction drawings.

 

2. Party B shall submit
the roster of construction personnel, copy of ID card and fingerprint attendance record to Party A for review and filing, otherwise,
it shall not be considered as the construction personnel of the project, and the construction site shall be equipped with face
recording machine and finger touching machine for attendance registration of attendance construction personnel, and the monthly
attendance list and salary signing sheet shall be submitted to Party A monthly.

 

3. During the construction
period, the water and electricity expenses shall be paid by Party B.

 

4. The fixed salary
of the project includes the salary of the construction personnel, all labor insurance and welfare, overtime payment, rush fee and
all unforeseen expenses of Party B. Party B shall not ask Party A for salary increase on the grounds of shortening the construction
period or other reasons. Labor insurance expenses and safety responsibilities shall be borne by Party B.

 

5. Without the consent
of Party A, Party B shall not subcontract the project to a third party for construction (except labor subcontracting and professional
subcontracting), otherwise, Party A has the right to cancel the contract.

 

6. If the quality of
the project made by Party B meets the acceptance standards of Party A, the owner, the supervision and quality inspection department,
Party B completes the project quantity on schedule, the safe and civilized construction meets the requirements of Party A, and
Party B complies with the provisions of the contract and carries out the project according to the rules and regulations of Party
A, then Party A shall pay Party B the project payment in accordance with the terms of the contract. At the same time, Party B shall
be rewarded for safe and civilized construction according to the contract.

 

    11

     

    

 

7. Upon completion of
the project, Party B shall notify Party A in writing that Party A shall arrange for acceptance within seven days if Party B’s project
data and project quality meet the acceptance conditions. In the case that Party B’s project meets the acceptance conditions, if
Party A fails to organize acceptance within the above time period, Party A shall bear the expenses arising therefrom.

 

8. When Party A pays
the progress payment to Party B in each installment, Party B shall submit the workers’ roster and the salary amount balance sheet
indicating the construction progress of each worker to the finance department as the payment procedure and submit it to Party B.
Party B shall settle the wages of the workers after the completion of each type of work.

 

9. Construct strictly
in accordance with the change notice of the construction drawings and design, and strictly implement the existing Construction
Technology Acceptance Specification. Respect and obey the supervision and command of the construction, supervision unit
and the management personnel of Party A, and shall not insult or extremity excesses against the aforesaid personnel, so as to ensure
the safe and civilized construction. Party B shall make all kinds of technical disclosure and safety advice to all the workers
who enter the site. Only the workers who have obtained the construction permit of Party A can enter the site for construction work.

 

10. Strict safety education
for the team. When entering the site, every worker must earnestly study, abide by and implement the Provisional Regulations on
Safety Management (in conformity with) and other systems, raise the workers’ awareness of safety in production, ensure that they
do not violate the safety operation regulations, avoid safety accidents, and assume administrative and economic responsibility
for all work-related accidents, large or small, that violate the safety operation regulations and safety systems. Party B shall
bear the economic and legal liabilities for all accidents caused by accidental negligence of the shift workers during working hours.

 

XII. Miscellaneous

 

1. Party A and Party
B shall bear the fees payable by relevant government departments respectively.

 

2. After the Contract
is signed, Party B shall have the duty of confidentiality, and shall not disclose the contents of the Contract, circulate it to
the outside world or send copies to the outside world. In case of any citation, Party A shall be deemed to be in breach of contract
by Party B, and Party A shall have the right to cancel and terminate the Contract, and Party A shall have the right to deduct and
punish Party B for the breach of contract from the course payment of Party B.

 

3. During the period
when Party B fails to receive Party A’s engineering payment (within one month, except for more than one month), it is necessary
to collect funds on its own according to the contract to solve the problem of workers’ wages and materials payment. Party A shall
not delay the payment of wages or other improper acts and affect the progress of the project on the ground of advance payment.
Otherwise, Party B shall be deemed to have breached the contract as agreed in the contract, and Party A shall have the right to
unilaterally terminate the contract and relevant terms, and the Contractor shall bear all liabilities for breach of contract. Party
B shall be deemed to be fully aware of the project and capable of assuming all economic and legal liabilities of the project when
signing the Contract. The comprehensive unit price of the project includes all expenses. Party B shall not offer compensation or
disturb Party A’s project progress due to the rush period or other reasons. Otherwise, Party B shall be deemed to have breached
the contract, and Party A shall have the right to terminate the contract and deal with it according to the breach of contract,
and Party B shall bear all the responsibilities arising therefrom.

 

    12

     

    

 

XIII. Guarantee of
project construction: in order to ensure the smooth completion of the project construction, Party B shall pay Party A the project
construction deposit of yuan (unit:10,000) or issue a performance bond of 3,000,000 yuan within two months after Party B enters
the site and starts construction.

 

XIV. Guarantee of
Payment: 

 

1. In order to ensure
the interests of Party A and Party B, and Party B shall receive the project payment. Party A agrees that Party B shall supervise
the sales of the building, and both parties shall jointly manage account of sales department, and 80% of the sales amount shall
be used for project payment first.

 

2. If Party A fails
to pay in accordance with the contract, Party A shall be deemed to have breached the contract. Party A unconditionally agrees to
compensate Party B for the actual project payment due to Party B at 70% of the market price for the shops and real estate of the
project. Party A shall unconditionally handle the relevant procedures for transferring the real estate right under the name of
Party B, hand over the property certificate to Party B for receipt, and deliver the shop and the real estate to Party B for use.
All the expenses arising from handling the property right certificate of the shop and the real estate shall be borne by the owner.

 

3. All the project funds
of Party A must be paid to the bank account designated by Party B, otherwise it will not be recognized, and Party B has the right
to investigate Party A’s corresponding liability for breach of contract. Account information is as follows: Account name: Jiangsu
Nantong Sanjian Holdings (Group) Co., Ltd; Account: 46001007636052503749; Opening bank: Fengxiang Road Sub-branch, Haikou City,
China Construction Bank, Hainan Province.

 

XV. Supplementary
provisions: 

 

1. Any issue not covered
by this agreement, will be settled between two parties through negotiation. The supplemental agreement shall have the same legal
effect with the agreement.

 

2. In case of any dispute
arising from this Agreement and other relevant matters under this Agreement, Party A and Party B shall settle the dispute through
consultation or file a lawsuit with the people’s court of the place where Party B’s enterprise is located.

 

3. This Agreement shall
be made in six copies, three for each party.

 

4. This agreement shall
come into force upon the signature and seal of both parties, and shall become invalid after the completion of the project, the
payment of all by Party A and the completion of the legal return visit period.

 

(No text blow)

 

    13

     

    

 

 

 

    14

     

    

 

Project quality warranty 

 

Employer (full name): Shenzhen Jiana
Technology Co., Ltd. 

 

Contractor (full name): Jiangsu Nantong
Sanjian Holdings (Group) Co., Ltd 

 

In order to ensure the
normal use of the commercial street (project name) of Hakka immigrant culture plaza business street within the reasonable service
period, the Employer and the Contractor shall sign the project quality warranty through consultation. The Contractor shall bear
warranty responsibility for project quality defects within quality warranty period in accordance with relevant stipulations and
agreements by the two parties.

 

I. Scope and content
of project quality warranty 

 

The scope of quality
warranty includes foundation projects, main structure works, roof waterproofing project, toilets, anti-seepage of rooms and external
walls with waterproofing requirements, as well as electrical pipelines, water supply and drainage pipelines, equipment installation
works, heating and cooling systems engineering, etc. Other agreements about quality warranty entered between the two parties are
as follows:

 

It shall be implemented
in accordance with the relevant national warranty provisions. 

 

II. Quality warranty
period 

 

Quality warranty period
is calculated from the date of actual completion of the project. For the project completed and accepted individually, quality warranty
period shall be calculated separately according to individual project.

 

The Contractor shall
guarantee the project contents of the quality warranty scope in accordance with the Regulations on Quality Management of Construction
Projects.

 

The warranty period
of other quality warranty contents may be agreed upon by oneself:

 

According to the
general terms: (I) The foundation engineering and main structure is in the reasonable using period of this project regulated by
the design document. (II) The toilets, rooms, roofs and external walls with waterproof requirements shall be guaranteed against
leakage for five years. (III) Electrical conduits, water supply and drainage pipelines and decoration project shall be guaranteed
for two years. 

 

III. Quality warranty
responsibility 

 

1. The Contractor shall
send personnel to repair within 7 days after receiving repair notice for items within warranty scope and contents. If the Contractor
fails to send personnel to repair within the agreed limit period, the Employer can entrust other personnel to repair and repair
expense shall be deducted from the quality warranty fund.

 

2. If emergency repair
accidents occur (such as leakage of water and gas and so on), the Contractor shall immediately arrive at the site of the accident
after receiving the notice of the accident. The employer shall undertake repair expense for accidents not caused by contractor’s
construction quality.

 

    15

     

    

 

3. The Contractor shall
ensure the quality of ground foundation project and main structures within the rational project operation period regulated by the
state. The Contractor shall pay for personal and property damages caused by the Contractor within the rational project operation
period.

 

4. In addition to the
foundation project and the main structure engineering, the Contractor shall perform the warranty obligations for the items and
contents within the scope of quality assurance, and shall also pay the warranty fund. The engineering quality warranty fund shall
generally not exceed 3% of the engineering price paid for the project.

 

5. The agreed percentage
of warranty fund in this project is 3% of the contract price, with no interest rate.

 

6. If the quality warranty
fund of the project is determined according to the warranty project sheet, both parties shall agree on the appropriate proportion,
amount and interest rate of the warranty:

 

none 

 

7. The Employer shall
return the remaining warranty fund and interest to the Contractor within 14 days after the expiration of the quality warranty period.

 

IV. Miscellaneous

 

1. In case of construction
quality problems during the warranty period, Party B shall repair them free of charge. 

 

2. Party B shall
be present for repair within three days after receiving the repair notice from Party A, otherwise Party A shall have the right
to entrust a third party for repair, and the cost thereof shall be deducted from the warranty fund at the rate of three times the
normal price. 

 

As annex of the contract,
the project quality warranty certificate shall be jointly signed by the Employer and the Contractor in the construction contract.

 

 

 

    16

     

    

 

Review opinions of the construction
administrative department: 

 

 

	Handler:	Examining authority (sealed)
	 	 
	 	MM/DD/YYYY 

 

The authentication opinions of industrial
and commercial administrative department: 

 

 

	Handler:	Verification authority (sealed)
	 	 
	 	MM/DD/YYYY 

 

 

17

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00303-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00303-of-00352.parquet"}]]