Document:

EX-10.14

 EXHIBIT 10.14 

THIRD AMENDMENT TO GAS GATHERING AND TREATING AGREEMENT 

THIS THIRD AMENDMENT TO GAS GATHERING AND TREATING AGREEMENT (this “Third Amendment”) is made by and between SWEPI LP
(“Shipper”) and CENTERPOINT ENERGY FIELD SERVICES, LLC, successor by conversion to CenterPoint Energy Field Services, Inc. (“Gatherer”) effective this 10th day of March, 2011
(the “Effective Date”). 
 Gatherer and Shipper are parties to that certain Gas Gathering and Treating Agreement dated September
I, 2009, as previously amended by the Parties on January 1, 2010, and April 1, 2010 (as so amended, the “Agreement”). Unless defined herein, all capitalized terms herein will have the same meaning as stated in the GGA; 

Prior to the Effective Date, Shipper installed and maintained metering equipment (“Shipper Check Meters”) upstream of
Gatherer’s Measurement Facilities at the Receipt Points. Based upon the information from Shipper Check Meters, Shipper dispatches personnel to physically increase or decrease the flow of Gas on Shipper’s Wells; 

Shipper desires to remove the Shipper Check Meters and install programmable logic controllers (“PLCs”) upstream of Gatherer’s
Measurement Facilities and on Shipper’s flow lines that will incrementally increase or decrease the flow of Gas on Shipper’s Wells. The PLCs will require Gatherer to transmit certain volumetric information from its Measurement Facilities
to the PLCs from which the PLCs will control Gas flow; and 
 Gatherer is willing to provide the volumetric information to Shipper’s
PLCs, provided Shipper indemnifies and releases Gatherer from all liability from Shipper’s installation, operation, repair, replacement, maintenance and removal of the PLCs, and for the accuracy, completeness, or consistency of the information
provided by Gatherer, as further provided herein. 
 The parties now desire to amend the GGA as set forth herein. 

NOW, THEREFORE, for adequate consideration received and acknowledged, the parties hereto agree as follows: 

 

	1.	Section 4.4 is added to the GGA: 

 “4.4 Programmable Logic Controllers. 

(a) During the Term, Shipper may install and operate programmable logic controllers (each a “PLC” and collectively
the “PLCs”) upstream of Gatherer’s Measurement Facilities at the Receipt Points: (i) at Shipper’s sole risk and expense; (ii) in a manner that does not interfere with Gatherer’s operations or measurement on each
Well site; and (iii) in compliance with all industry requirements. 

 (b) Gatherer agrees that Shipper may connect the PLCs to the Gatherer’s
Measurement Facilities in order to receive Gatherer’s measurement data from each Well to which the Measurement Facilities are attached. At each Receipt Point where Shipper decides to install a PLC, Shipper will place its PLC at a mutually
agreed location upstream of Gatherer’s Measurement Facilities at the Receipt Point and on Shipper’s flow line. Shipper will connect its PLCs at a time that is mutually convenient for both Parties with a Gatherer representative present.

 (c) Notwithstanding any other provision in this Agreement, Shipper assumes sole responsibility for the condition,
installation, operation, service, repair, construction, replacement and maintenance of the PLCs and for compliance with all local, state and federal laws and regulations applicable to the acquisition, ownership, operation and maintenance thereof
Shipper agrees to pay, compensate, reimburse, indemnify, and hold harmless Gatherer (and its directors, officers, shareholders, members, employees, agents and representatives) from and against any and all loss of or damage to the extent caused by
Shipper’s PLCs or by Shipper, Shipper’s employees, contractors, or agents in the installation, operation, maintenance, repair, replacement or removal of any and all PLCs. 

(d) Notwithstanding any other provision in this Agreement, Gatherer makes no warranty or representation whatsoever, express,
implied, statutory or otherwise including but not limited to any representation, warranty or covenant with respect to condition quality, or any other representation, warranty or covenant or any kind or character expressed or implied with respect
thereto as to its Measurement Facilities or volumetric information. 
 (e) Notwithstanding any other provision in this
Agreement, Shipper waives and releases Gatherer from, and covenants and agrees to indemnify, defend and hold harmless Gatherer (and its directors, officers, shareholders, members, employees, agents and representatives) from and against any and all
actions, suits, assessments, levies, proceedings, hearings, investigations, charges, complaints, claims, demands, injunctions, judgments, orders, decrees, rulings, damages, injury to or death of any person whomsoever, or loss of or damage to any
property in any way, dues, penalties, fines, costs, amounts paid in settlement, liabilities, environmental damage, regulatory penalty, pollution or contamination, obligations, taxes, liens, losses, expenses, and fees, including court costs and
attorneys’ fees and expenses, and any and all other liability, whether known or unknown, foreseen or unforeseen, existing or future, directly or indirectly resulting from, arising out of, or related to arising out of the ownership, operation,
installation, service, repair, construction, replacement and maintenance of the PLCs, and/or from any release, spill or contamination to air, land, or water arising from or caused by the PLCs. 

(f) Shipper’s responsibility for release, contamination or spill to air, land, or water from the PLCs includes
investigations, monitoring, clean-up, remediation, removal or restoration work that is required by any federal, state or local governmental agency or political subdivision with applicable jurisdiction because
of the presence, suspected presence, release or suspected release to air, soil, surface water, or groundwater on or emanating from a PLC. The performance of any such investigations, monitoring,
clean-

  
 2 

 
up, remediation, removal or restoration work on Gatherer’s property or facilities will be by Gatherer, and in the name of Gatherer, subject to Shipper’s indemnity obligations. For all
such work on Gatherer’s property or facilities, Gatherer will obtain all necessary licenses, manifests, permits and approvals to perform such work. All investigations, monitoring, clean-up, remediation,
removal or restoration work and the disposal of all waste generated by such work by either Party will be in accordance with all applicable Laws. 

(g) Gatherer is not obligated to produce any daily raw volumetric information from its Measurement Facilities to the PLCs.
However, nothing in this Subsection 4.4 amends Gatherer’s obligations stated elsewhere in this Agreement to provide information, including those obligations under Subsections 8.5 and 9.3. In the event that Gatherer chooses to produce
measurement information to the PLCs, this Agreement does not create a continuing obligation to produce any other information to the PLCs or to update any such information that has been previously produced. All Gatherer’s measurement information
shall belong to and remain the sole property of the Gatherer. Shipper shall acquire no proprietary interest in or right to any of the measurement information received from Gatherer. Shipper acknowledges that neither Gatherer nor any of its
Representatives makes any express or implied representation or warranty as to the condition, quality, accuracy or completeness of any measurement information, and Shipper agrees that none of such persons shall have any liability to Shipper or any of
its Representatives relating to or arising from its or their use of any measurement information or for any errors therein or omissions therefrom. Shipper also agrees that it is not entitled to rely on the accuracy or completeness of any measurement
information. Shipper acknowledges and agrees that the measurement information is being provided solely for the purpose of assisting its PLCs.” 
  

	2.	The GGA, as amended previously and herein remains in full force and effect. 

  
 3 

 IN WITNESS WHEREOF, this Third Amendment to Gas Gathering and Treating Agreement is executed as
of the 10th day of March, 2011. 
  

									
	 Shipper:
 SWEPI LP
	 		 	 Gatherer:
 Centerpoint Energy Field
Services, LLC

					
	By:	 	 /s/ Stephen Friedman
	 		 	By:	  	 /s/ William H. May, Jr

	Name:	 	Stephen Friedman	 		 		  	William H. May, Jr.
	Title:	 	Attorney-In-Fact	 		 		  	Senior Vice President and
		 		 		 		  	Chief Commercial Officer

  
 4EX-10.15

 EXHIBIT 10.15 

FOURTH AMENDMENT TO GAS GATHERING AND TREATING AGREEMENT 

THIS FOURTH AMENDMENT TO GAS GATHERING AND TREATING AGREEMENT (this “Fourth Amendment”) is made by and between SWEPT LP
(“Shipper”) and CENTERPOINT ENERGY FIELD SERVICES, LLC, successor by co version to CenterPoint Energy Field Services, Inc. (“Gatherer”) effective this 1st day of September,
2011. 
 Background 

Gatherer and Shipper are Parties to that certain Gas Gathering and Treating Agreement dated September 1, 2009, as amended (the
“GGA”). Capitalized terms used herein, if not defined herein, will have the meaning given to such terms in the GGA; and 
 The
Parties now desire to further amend the GGA as set forth herein. 
 NOW, THEREFORE, for adequate consideration received and acknowledged,
the Parties hereto agree as follows: 
  

	1.	Shipper’s Production Forecast. Section 3.2(c) is hereby added to the GGA to state in its entirety, “No less frequently than once each calendar quarter, Shipper will provide to Gatherer written
projections of the total Gas volumes that Shipper reasonably expects to deliver for Gathering hereunder during each month of the immediately following 12-month period (each, a “Shipper’s Production
Forecast”). 

  

	2.	Clear Lake 200 Plant. 

  

	 	a.	Gatherer will install and operate at its Clear Lake Facility a 1,000 gpm amine treating facility with compression designed to provide Shipper and Shipper Partner combined treating capacity of 180 MMscf/d (the
“Clear Lake 200 Plant”). The Clear Lake 200 Plant is not an Additional Service pursuant to Section 7 the GGA and there will be no additional Gathering Fee for the Clear Lake 200 Plant. 

 

	 	b.	Effective October 1, 2011, Shipper and Shipper Partner will have combined Preferential Capacity for up to 100% of the treating capacity at Gatherer’s Clear Lake facilities. 

 

	 	c.	 Clear Lake Completion Date. Gatherer shall utilize commercially reasonable efforts to complete construction of
the Clear Lake 200 Plant and associated compression and interconnects by October 1, 2011 (the “Clear Lake Completion Date”). If Gatherer anticipates, in its reasonable judgment and opinion, that it will not meet the Clear Lake
Completion Date, then Gatherer shall provide Shipper as much advance notice of such delay as possible, along with a new estimated completion date. For each Day after October 1, 2011, in the absence of Force Majeure, that Shipper is unable to
deliver gas into the Magnolia Gathering System due to the failure of Gatherer to complete the Clear Lake 200 Plant, Shipper shall be entitled to one (1) Day of Gathering service without paying the associated

	 	
Gathering Fee then in effect for such well or wells impacted as a result of the failure to meet the Clear Lake Completion Date, beginning with the first delivery of Gas from the well or wells,
with such Days of Gathering service without paying the associated Gathering Fee not to exceed ninety (90) Days of Gathering service for such well or wells. 

  

	3.	Third Party Gas. Effective October 1, 2011, the Parties amend and restate in its entirety Section 9.4 of the GGA as follows: 

 

	 	a.	Subject to the limitation in Section 9.4(d) below, any Gas delivered by a party other than the Preferential Capacity Shippers (collectively, “Third Party Gas”), as well as all Undedicated Shipper Gas, shall be
treated as Shipper Gas for purposes of calculating the Annual Volume Commitments and Total Volume Commitment. 

  

	 	b.	The Parties acknowledge that Shipper and Gatherer are also parties to that certain Gas Gathering and Treating Agreement between Shipper and Gatherer dated April 29, 2010 (“Olympia GGA”) covering the
Olympia Gathering System. The term “Olympia Gathering System” as used herein will have the meaning given to such term in the Olympia GGA. Shipper Partner and Gatherer are also parties to a like agreement covering the Olympia Gathering
System (the “Partner Olympia GGA”). Shipper Partner and Gatherer are also parties to a like agreement covering the Magnolia Gathering System (the “Partner Magnolia GGA”). 

 

	 	c.	Third Party Gas that originates west of the Red River, whether such gas is delivered into the Olympia Gathering System or the Magnolia Gathering System, will be referred to herein as “Western TPG.”

  

	 	d.	Notwithstanding that Third Party Gas will be credited as provided in Paragraphs (a) and (e), the Parties agree that beginning October 1 of 2011 and September 1 of each succeeding year of the Primary Term
of the GGA, all Western TPG will be excluded from the quantity of Third Party Gas credited toward the Annual Volume Commitment and the Total Volume Commitment of Shipper under this GGA, the Olympia GGA, Partner Magnolia GGA and Partner Olympia GGA
until the point in time each Contract Year that the Western TPG delivered under the GGA, Olympia GGA, Partner Magnolia GGA and Partner Olympia GGA after September 1 of the applicable Magnolia GGA Contract Year collectively equals
62.4 million MMBtu. After that point in time each Contract Year, if it occurs, Western TPG delivered into the Magnolia Gathering System for the remainder of the applicable Contract Year will be credited as with all other Third Party Gas
delivered hereunder. This exclusion of a portion of Western TPG from the calculation of the Annual Volume Commitment and Total Volume Commitment of Shipper and Shipper Partner does not otherwise affect the credit for Third Party Gas provided in this
Section 9.4. 

  

	 	e.	 Gatherer shall apply Third Party Gas to the Shipper Gas Volume Commitment solely on an MMBtu to MMBtu (i.e., 1:1)
basis. Gas delivered by Preferential Capacity Shippers from outside the Committed Area will first be credited to the 

  
 2 

	 	
respective Shipper or Shipper Partner. The balance of Third Party Gas shall be allocated between Shipper and Shipper Partner calculated as a ratio: (i) the numerator of which is Shipper Gas
delivered to the Magnolia Gathering System, and (ii) the denominator of which is (x) Gas delivered by Shipper Partner from within the Committed Area plus (y) Shipper Gas delivered to the Magnolia Gathering System. Any amount by which
the volume of actual Gas delivered by Shipper in a Contract Year exceeds the Annual Volume Commitment for the corresponding year (“Excess Delivered Volumes”) shall be deemed part of the volume of actual Gas delivered for the next annual
Volume Shortfall calculation. Unapplied Excess Delivered Volumes shall continue to carry forward until used to satisfy a committed quantity or until all commitment years have elapsed. If Shipper has met its Total Volume Commitments under the terms
of this Section 9 and/or Section 6 of this Agreement, then such Excess Delivered Volumes shall be applied to Shipper Partner’s Annual Volume Commitments. 

 

	4.	North River Bore Pipeline. 

  

	 	a.	Gatherer will construct a 24” diameter Gathering pipeline connecting Gatherer’s Clear Lake Facilities in Red River Parish, Louisiana and its Line AB in S16-14N-9W of Red River Parish, Louisiana (the “North River Bore Pipeline”). The North River Bore Pipeline is not an Additional Service pursuant to Section 7 of the GGA and there will be no
additional Gathering Fee for the North River Bore Pipeline. 

  

	 	b.	The current planned route of the North River Bore Pipeline will generally follow a route from Gatherer’s Clear Lake Facilities in Red River Parish, Louisiana through S7-14N-10W, Red River Parish, Louisiana, proceeding through S17-14N-10W, Red River Parish, Louisiana and then continuing through
S16-14N-9W, Red River Parish, Louisiana to its connection to Line AB; provided, Gatherer shall determine the actual route of the North River Bore Pipeline.

  

	 	c.	Gatherer shall utilize commercially reasonable efforts to complete construction of the North River Bore Pipeline and associated interconnects by November 1, 2011 (the “North River Bore Pipeline Completion
Date”). If Gatherer anticipates, in its reasonable judgment and opinion, that it will not meet the North River Bore Pipeline Completion Date, then Gatherer shall provide Shipper as much advance notice of such delay as possible, along with a new
estimated completion date. 

  

	5.	Except as expressly amended herein, the GGA remains in effect as originally written and previously amended. 

  
 3 

 IN WITNESS WHEREOF, this Fourth amendment is executed as of the 15th day of December, 2011 
  

			
	 SHIPPER:
 SWEPI LP

		
	By:	 	 /s/ Robert Cowan

	Name:	 	Robert Cowan
	Title:	 	Attorney-In-Fact

  

			
	 GATHERER:

CENTERPOINT ENERGY FIELD SERVICES, LLC

		
	By:	 	 /s/ William H. May, Jr.

	Name:	 	William H. May, Jr.
	Title:	 	Sr. VP & CCO

  
 4

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00269-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00269-of-00352.parquet"}]]