Document:

EX-10.3

 Exhibit 10.3 

EXECUTION VERSION 
  

 
  

AMENDED AND RESTATED 

COMMON SECURITY AND ACCOUNT AGREEMENT 

among 
 CHENIERE CORPUS CHRISTI
HOLDINGS, LLC, 
 as Company, 

CORPUS CHRISTI LIQUEFACTION, LLC, 

CHENIERE CORPUS CHRISTI PIPELINE, L.P., and 

CORPUS CHRISTI PIPELINE GP, LLC, 

as Guarantors, 
 THE SENIOR
CREDITOR GROUP REPRESENTATIVES PARTY HERETO AND THAT 
 ACCEDE HERETO FROM TIME TO TIME, FOR THE BENEFIT OF ALL SENIOR CREDITORS, 

SOCIÉTÉ GÉNÉRALE, 

as Intercreditor Agent for the Facility Lenders and any Hedging Banks, 

SOCIÉTÉ GÉNÉRALE, 

as Security Trustee,  

and  
 MIZUHO BANK, LTD.,

 as Account Bank, 

Dated as of May 22, 2018 
  

 
  

 TABLE OF CONTENTS 

 

									
	1.	 	 DEFINITIONS AND INTERPRETATION
	  	 	1	 
			
	2.	 	 SENIOR DEBT
	  	 	2	 
		 	 2.1
	  	Senior Debt Secured Hereby	  	 	2	
		 	 2.2
	  	Incremental Senior Debt	  	 	2	
		 	 2.3
	  	Payments and Prepayments	  	 	4	
		 	 2.4
	  	Initial Senior Creditor Group Representative; Replacement or Appointment of Senior Creditor Group Representative	  	 	8	
		 	 2.5
	  	Other Intercreditor Agents	  	 	9	
		 	 2.6
	  	Transfers and Holders of Senior Debt Obligations	  	 	11	
		 	 2.7
	  	Accession of Senior Creditor Group Representatives	  	 	11	
		 	 2.8
	  	Changes to Senior Debt Instruments and Permitted Senior Debt Hedging Instruments	  	 	13	
		 	 2.9
	  	Discharge of Certain Senior Debt Obligations	  	 	14	
		 	 2.10
	  	Sponsor and its Affiliates	  	 	15	
		 	 2.11
	  	Secured Party Guarantees	  	 	15	
			
	3.	 	 SECURITY INTERESTS
	  	 	15	 
		 	 3.1
	  	Pro Rata First-Ranking Security Interests	  	 	15	
		 	 3.2
	  	Security Interests to be Granted by the Securing Parties	  	 	16	
		 	 3.3
	  	Security Interests to be Granted by Holdco	  	 	29	
		 	 3.4
	  	Direct Agreements	  	 	29	
		 	 3.5
	  	Perfection and Maintenance of Security Interests	  	 	31	
		 	 3.6
	  	Rights in Collateral Prior to Security Enforcement Action	  	 	38	
		 	 3.7
	  	Liability of Securing Parties Under Contracts or Agreements Included in the Collateral	  	 	39	
		 	 3.8
	  	Release or Modification of Security Interests	  	 	40	
			
	4.	 	 CASH FLOW AND ACCOUNTS
	  	 	41	 
		 	 4.1
	  	General Principles	  	 	41	
		 	 4.2
	  	Authorized Investments	  	 	43	
		 	 4.3
	  	Accounts	  	 	45	
		 	 4.4
	  	Procedures for Deposits and Withdrawals from Accounts	  	 	47	
		 	 4.5
	  	Deposits and Withdrawals	  	 	49	
		 	 4.6
	  	Control and Investment of Funds in Accounts	  	 	58	
		 	 4.7
	  	Cash Waterfall	  	 	61	
		 	 4.8
	  	Accounts During the Continuance of a Declared Event of Default	  	 	64	
		 	 4.9
	  	Acceptable Debt Service Reserve LC	  	 	65	
		 	 4.10
	  	Adequate Instruction; Sufficiency of Funds	  	 	68	
		 	 4.11
	  	Account with Third Party Account Bank	  	 	69	

  
 A&R Common
Security and Account Agreement 

  
 -i- 

									
			
	5.	 	 INSURANCE AND CONDEMNATION PROCEEDS AND PERFORMANCE LIQUIDATED DAMAGES
	  	 	72	 
		 	 5.1
	  	Additional Insureds	  	 	72	
		 	 5.2
	  	Insurance and Condemnation Proceeds	  	 	72	
		 	 5.3
	  	Performance Liquidated Damages	  	 	78	
			
	6.	 	 SECURITY TRUSTEE ACTION
	  	 	78	 
		 	 6.1
	  	Security Trustee Action Generally	  	 	78	
		 	 6.2
	  	Initiation of Security Enforcement Action	  	 	80	
		 	 6.3
	  	Conduct of Security Enforcement Action	  	 	83	
		 	 6.4
	  	Incidents of Sale	  	 	86	
		 	 6.5
	  	Security Trustee May File Proofs of Claim	  	 	89	
		 	 6.6
	  	Security Trustee May Enforce Claims	  	 	89	
		 	 6.7
	  	Enforcement Proceeds Account	  	 	89	
		 	 6.8
	  	Rights of Enforcement under the Security Documents	  	 	91	
		 	 6.9
	  	Rights of Set-Off	  	 	91	
			
	7.	 	 INTERCREDITOR ARRANGEMENTS
	  	 	92	 
		 	 7.1
	  	Other Intercreditor Arrangements	  	 	92	
		 	 7.2
	  	Modification Approval Levels	  	 	93	
		 	 7.3
	  	Hedging Banks	  	 	96	
		 	 7.4
	  	Sponsor Voting	  	 	97	
		 	 7.5
	  	Notice and Consultation	  	 	97	
		 	 7.6
	  	Intercreditor Agent Indemnity	  	 	98	
			
	8.	 	 THE SECURITY TRUSTEE
	  	 	99	 
		 	 8.1
	  	Appointment and Duties	  	 	99	
		 	 8.2
	  	Delivery of Documentation	  	 	101	
		 	 8.3
	  	Attorney-in-Fact	  	 	101	
		 	 8.4
	  	Reliance	  	 	105	
		 	 8.5
	  	Liability	  	 	106	
		 	 8.6
	  	Consultation with Counsel, Etc	  	 	107	
		 	 8.7
	  	Resignation, Removal and Replacement of Security Trustee	  	 	108	
		 	 8.8
	  	Indemnity	  	 	110	
		 	 8.9
	  	Compensation and Expenses	  	 	113	
		 	 8.10
	  	Certificates	  	 	114	
		 	 8.11
	  	Stamp and Other Similar Taxes	  	 	114	
		 	 8.12
	  	Information	  	 	115	
		 	 8.13
	  	Books and Records	  	 	115	
		 	 8.14
	  	Limitation on Security Trustee’s Duties in Respect of Collateral	  	 	115	
		 	 8.15
	  	Security Documents	  	 	115	
		 	 8.16
	  	Exculpatory Provisions	  	 	116	
		 	 8.17
	  	Own Responsibility	  	 	116	
		 	 8.18
	  	Merger of the Security Trustee	  	 	117	
		 	 8.19
	  	Treatment of Senior Creditors by the Security Trustee	  	 	117	
		 	 8.20
	  	Compliance	  	 	117	
		 	 8.21
	  	Miscellaneous	  	 	118	

  
 A&R Common
Security and Account Agreement 

  
 -ii- 

									
	9.	 	 THE ACCOUNT BANK
	  	 	119	 
		 	 9.1
	  	Appointment and Role of the Account Bank	  	 	119	
		 	 9.2
	  	Undertakings of the Account Bank	  	 	119	
		 	 9.3
	  	No Fiduciary Duties	  	 	120	
		 	 9.4
	  	The Account Bank Individually	  	 	120	
		 	 9.5
	  	Rights and Discretions of the Account Bank	  	 	120	
		 	 9.6
	  	No Responsibility for Documentation	  	 	122	
		 	 9.7
	  	Exclusion of Liability	  	 	122	
		 	 9.8
	  	Indemnities	  	 	123	
		 	 9.9
	  	Resignation, Removal and Replacement of the Account Bank	  	 	126	
		 	 9.10
	  	Notice and Acknowledgment of Security	  	 	128	
		 	 9.11
	  	Compensation and Expenses	  	 	128	
			
	10.	 	 OBLIGATIONS UNDER SECURITY DOCUMENTS
	  	 	128	 
		 	 10.1
	  	Nature of Obligations	  	 	128	
		 	 10.2
	  	Suspense Account	  	 	132	
		 	 10.3
	  	Limitation on Recourse	  	 	132	
		 	 10.4
	  	No Interference; Payment Over; Exculpatory Provisions	  	 	134	
		 	 10.5
	  	Certain Agreements with Respect to Bankruptcy	  	 	135	
			
	11.	 	 GUARANTEES
	  	 	137	 
		 	 11.1
	  	Guarantor Obligations	  	 	137	
		 	 11.2
	  	Right of Contribution	  	 	138	
		 	 11.3
	  	Payment by Guarantors	  	 	138	
		 	 11.4
	  	No Subrogation	  	 	138	
		 	 11.5
	  	Amendments, etc. with respect to the Senior Debt Obligations	  	 	139	
		 	 11.6
	  	Guarantee Absolute and Unconditional	  	 	139	
		 	 11.7
	  	Authority of Guarantors or Company	  	 	142	
		 	 11.8
	  	Bankruptcy	  	 	142	
		 	 11.9
	  	Release	  	 	143	
		 	 11.10
	  	Reinstatement	  	 	144	
		 	 11.11
	  	Information	  	 	144	
		 	 11.12
	  	Instrument for Payment of Money	  	 	144	
		 	 11.13
	  	Limitation on Guarantee Obligations	  	 	144	
		 	 11.14
	  	Swap Obligations	  	 	145	
		 	 11.15
	  	Additional Guarantors	  	 	145	
			
	12.	 	 MISCELLANEOUS
	  	 	146	 
		 	 12.1
	  	Termination	  	 	146	
		 	 12.2
	  	Waiver of Immunity	  	 	146	
		 	 12.3
	  	Judgment Currency	  	 	146	
		 	 12.4
	  	Severability	  	 	147	
		 	 12.5
	  	Entire Agreement	  	 	147	
		 	 12.6
	  	Confidentiality	  	 	147	

  
 A&R Common
Security and Account Agreement 

  
 -iii- 

									
		 	 12.7
	  	Notices	  	 	150	
		 	 12.8
	  	Successors and Assigns; Benefits of Agreement	  	 	153	
		 	 12.9
	  	Remedies	  	 	153	
		 	 12.10
	  	Execution in Counterparts	  	 	154	
		 	 12.11
	  	GOVERNING LAW	  	 	154	
		 	 12.12
	  	WAIVER OF JURY TRIAL	  	 	155	
		 	 12.13
	  	Consent to Jurisdiction	  	 	155	
		 	 12.14
	  	Amendments	  	 	156	
		 	 12.15
	  	Conflicts	  	 	157	
		 	 12.16
	  	Further Assurances	  	 	157	
		 	 12.17
	  	Survival of Obligations	  	 	157	
		 	 12.18
	  	Other Indemnities	  	 	157	
		 	 12.19
	  	Amendment and Restatement	  	 	159	

  
 A&R Common
Security and Account Agreement 

  
 -iv- 

 SCHEDULES 
  

									
	A	 	 Common Definitions and Rules of Interpretation
	 			
	B	 	 Addresses for Notices of the Securing Parties and Holdco
	 			
	C	 	 List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt
Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office
	 			
	D	 	 Forms of Accession Agreements
	 			
		 	 D-1
	  	Form of Senior Creditor Group Representative Accession Agreement	 			
		 	 D-2
	  	Form of Security Trustee Accession Agreement	 			
		 	 D-3
	  	Form of Account Bank Accession Agreement	 			
	E	 	 Commercial Tort Claims
	 			
	F	 	 Form of Holdco Pledge and Security Agreement
	 			
	G	 	 Forms of Direct Agreement
	 			
		 	 G-1
	  	Form of Direct Agreement for Material Project Agreements with Affiliates	 			
		 	 G-2
	  	Form of Direct Agreement for Material Project Agreements with non-Affiliates	 			
		 	 G-3
	  	Form of Direct Agreement for Guarantees	 			
		 	 G-4
	  	Form of Direct Agreement for Technology Licensor under the ConocoPhillips License Agreements	 			
		 	 G-5-1
	  	Form of Direct Agreement for DES-Linked LNG SPA	 			
		 	 G-5-2
	  	Form of Direct Agreement for Affiliate Non-Qualifying LNG SPAs	 			
		 	 G-6
	  	Forms of Direct Agreement for Contractor, and any Guarantor of such Contractor’s Obligations, under an Engineering, Procurement and Construction Contract	 			
	H	 	 Details of Initial Accounts
	 			
	I-1	 	 Form of Amended and Restated Deed of Trust (CCL)
	 			
	I-2	 	 Form of Amended and Restated Deed of Trust (CCP)
	 			
	J	 	 Intellectual Property
	 			
	K	 	 Form of Withdrawal and Transfer Certificate
	 			
	L	 	 UCC Filing Offices
	 			
	M	 	 Restricted Documents
	 			

  

  
 A&R Common
Security and Account Agreement 

  
 -v- 

 § 1 
  

 THIS AMENDED AND RESTATED COMMON SECURITY AND ACCOUNT AGREEMENT, dated as of May 22, 2018 (the
“Common Security and Account Agreement” or this “Agreement”), is made among: 
  

	 	(a)	Cheniere Corpus Christi Holdings, LLC, a limited liability company organized under the laws of the State of Delaware (the “Company”); 

 

	 	(b)	Corpus Christi Liquefaction, LLC, a limited liability company organized in the State of Delaware, Cheniere Corpus Christi Pipeline, L.P., a limited partnership organized under the laws of the State of
Delaware, and Corpus Christi Pipeline GP, LLC, a limited liability company organized under the laws of the State of Delaware (each a “Guarantor” and together the “Guarantors” and, together with the Company,
the “Securing Parties”); 

  

	 	(c)	The Senior Creditor Group Representatives listed in Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt
Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office) and each Senior Creditor Group Representative that accedes hereto from time to time, for its own benefit and the benefit of each such representative’s
respective Senior Creditor Group; 

  

	 	(d)	Société Générale, as Intercreditor Agent for the Facility Lenders and any Hedging Banks; 

  

	 	(e)	Société Générale, as Security Trustee; and 

  

	 	(f)	Mizuho Bank, Ltd., as Account Bank. 

 The Parties hereto hereby agree as follows: 

 

	1.	DEFINITIONS AND INTERPRETATION 

  

	 	(a)	In this Agreement and the Schedules hereto, except as otherwise expressly provided herein, capitalized terms used in this Agreement and its Schedules shall have the meanings assigned to them in Section 1.3 of
Schedule A (Common Definitions and Rules of Interpretation – Definitions). 

  

	 	(b)	In this Agreement and the Schedules hereto, except as otherwise expressly provided herein, the interpretation provisions contained in Section 1.2 of Schedule A (Common Definitions and Rules of Interpretation
– Interpretation) shall apply. 

  

	 	(c)	In addition to the foregoing, in this Agreement, the following capitalized terms shall have the meaning given to them in the UCC (and, if defined in more than one Article of the UCC, shall have the meaning given in
Article 9 thereof): As-extracted Collateral, Bank, Bank’s Jurisdiction, Certificated Security, Certificates of Title, Chattel Paper, Continuation Statement, Commercial Tort Claims, Commodity Account, Deposit Account, Document, Entitlement
Holder, Entitlement Order, Equipment, Financing Statement, Financial Asset, Fixtures, General Intangibles, Goods, Instrument, Inventory, Investment Property, Letter-of-Credit Right, Money, Payment Intangibles,
Proceeds, Record, Securities Account, Security, Securities Intermediary, Securities Intermediary’s Jurisdiction, Security Entitlement, Software and Supporting Obligations. 

  
 -1- 

 § 1(c) 
  

	2.	SENIOR DEBT 

  

	 	2.1	Senior Debt Secured Hereby 

  

	 	(a)	All Senior Debt Obligations shall be secured by and entitled to the benefits of this Agreement and to the Security Interests granted by or pursuant to this Agreement and the other Security Documents, in each case
subject to the terms and conditions of this Agreement. 

  

	 	(b)	The Senior Creditors, the Senior Creditor Group Representatives, the Senior Debt Commitments, the maximum principal amount of Senior Debt or the maximum notional amount, as applicable, the Senior Debt Instruments and
the Permitted Senior Debt Hedging Instruments benefitting from this Agreement on the date hereof are each identified in Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior
Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office). 

  

	 	2.2	Incremental Senior Debt 

  

	 	(a)	At any time, and from time to time, the Company may incur senior secured debt that is incremental to the Initial Senior Debt under either sub-clause (i) or sub-clause (ii) below as follows: 

  

	 	(i)	the Company may enter into commitments to incur such additional senior secured debt as it may be permitted to incur under all Senior Debt Instruments then in effect and subject to the terms and conditions in such Senior
Debt Instruments to the incurrence of such debt (all such permitted additional senior secured debt, “Additional Senior Debt”) and the Company’s obligations thereunder shall, subject to clause (b) below, become Senior Debt
Obligations secured by and entitled to the benefits of this Agreement and the other Security Documents and the Direct Agreements, upon satisfaction of each of the following conditions precedent: 

 

	 	(A)	delivery of a certification by the Company to the Security Trustee (with a copy to each Senior Creditor Group Representative) that such additional senior secured debt obligations have been incurred in compliance with,
and satisfy the conditions required to be met in order for such debt to be Senior Debt pursuant to, the relevant provisions of all Senior Debt Instruments then in effect, including in each case to the extent applicable Sections 6.2 (Working
Capital Debt), 6.3 (Replacement Senior Debt), 6.4 (PDE Senior Debt) or 6.5 (Expansion Senior Debt), as applicable, of the Common Terms Agreement in addition to any comparable provision in any other Senior Debt Instruments
then in effect; and 

  
 -2- 

 § 2.2(a)(ii) 

 

	 	(B)	satisfaction of all the requirements of Section 2.7 (Accession of Senior Creditor Group Representatives); and 

  

	 	(ii)	the Company may enter into Permitted Senior Debt Hedging Instruments and incur senior secured debt obligations thereunder and such obligations shall, subject to Section 7.3 (Hedging Banks), become Senior
Debt Obligations secured by and entitled to the benefits of this Agreement, the other Security Documents and the Direct Agreements upon satisfaction of each of the following conditions precedent: 

 

	 	(A)	delivery of a certification by the Company to the Security Trustee (with a copy to each Senior Creditor Group Representative) that such incremental senior secured debt obligations incurred under a Permitted Senior Debt
Hedging Instrument have been incurred in compliance with, and satisfy the conditions required to be met in order for such obligations to be incurred by the Company pursuant to, the relevant provisions of all Senior Debt Instruments then in effect,
including Section 12.22 (Hedging Arrangements) of the Common Terms Agreement in addition to any comparable provision in any other Senior Debt Instrument then in effect; and 

 

	 	(B)	satisfaction of all the requirements of Section 2.7 (Accession of Senior Creditor Group Representatives). 

  

	 	(b)	Replacement Senior Debt Senior Noteholders Benefitting from Escrow Account 

  

	 	(i)	In the event any Replacement Senior Debt is incurred pursuant to the issuance of Senior Notes under any Indenture, and the proceeds of such Indebtedness are held in escrow in a Senior Note Disbursement Account in
accordance with Section 4.5(a)(iii) (Deposits and Withdrawals – Disbursements of Senior Debt – Escrow of Senior Notes Issued as Replacement Senior Debt), the senior debt obligations acquired by the Senior
Noteholders who purchase such Senior Notes shall become Senior Debt Obligations secured by and entitled to the benefits of this Agreement, the other Security Documents and the Direct Agreements, and such Senior Noteholders shall become Senior
Creditors (A) solely for the limited purposes set forth in sub-clause (ii) below upon the satisfaction of the conditions precedent in sub-clause (a)(i)
above and (B) for all other purposes under the Finance Documents, solely upon the later of (1) satisfaction of the conditions precedent in sub-clause (a)(i) above and (2) the expiration of
the relevant escrow period, to the extent that such proceeds are not repaid to such Senior Noteholders at the end of the relevant escrow period. Accordingly, prior to the date identified in sub-clause (B)
above, such Senior Noteholders shall not be secured by and shall not have recourse to the Security Interests, the Securing Parties, Holdco or any assets of the Securing Parties or Holdco (including prior to such date, the Project Property) or the
right to instruct the Security Trustee except as set forth in sub-clause (ii) below. 

  
 -3- 

 § 2.2(b)(i) 

 

	 	(ii)	Prior to the expiration of the relevant escrow period, such Senior Noteholders shall (A) have recourse to the Security Interest granted to the Security Trustee pursuant to Section 3.2(b)(i) (Security
Interests to be Granted by the Securing Parties – Security Interests – General) over any Senior Note Disbursement Account, and the cash, Financial Assets and other property credited thereto or held therein as
security for the repayment of such Indebtedness, and (B) be entitled to instruct the Security Trustee to take action in respect thereof as a Senior Creditor in accordance with this Agreement. 

 

	 	2.3	Payments and Prepayments 

  

	 	(a)	Pro Rata Payment of Senior Debt Obligations 

  

	 	(i)	Subject to sub-clause (ii) and sub-clause (b)(ii) (Sharing of Non-Pro Rata Payments)
below, each payment or prepayment of Senior Debt Obligations (other than with respect to Senior Debt Obligations incurred under a Permitted Senior Debt Hedging Instrument, which is addressed in clause (f) (Payment of Permitted Senior Debt
Hedging Liabilities) below, and Secured Party Fees) from the Securing Parties to Senior Creditors shall be made to the Senior Creditors as a Pro Rata Payment and a Senior Creditor shall not be entitled to receive any payment or prepayment of any
such Senior Debt Obligations that is not made as a Pro Rata Payment; provided that: 

  

	 	(A)	subject to the requirements of any Senior Debt Instrument, any Senior Creditor may by written notice to the Security Trustee and the other Senior Creditor Group Representatives waive its right to a Pro Rata Payment
hereunder; and 

  

	 	(B)	if a Senior Debt Instrument expressly states that no pro rata payment thereunder shall be required in respect of a specified mandatory or voluntary prepayment (or type of pro rata prepayment) made under
other Senior Debt Instruments, then no such pro rata payment shall be required hereby (subject to compliance with any conditions established by the Senior Debt Instrument waiving the right to a pro rata prepayment in such
circumstances). 

 For the avoidance of doubt, if at any time at which any Senior Debt Obligations are due and payable to the
Senior Creditors there are insufficient funds to discharge all the amounts then due and payable to the Senior Creditors in accordance with Section 4.7 (Cash Waterfall) or Section 4.8 (Accounts During the Continuance of a Declared
Event of Default), as applicable, each Senior Creditor shall receive a Pro Rata Payment, to be applied in accordance with clause (d) (Partial Payments) below. 

  
 -4- 

 § 2.3(a)(ii)(A)(2) 

 

	 	(ii)	Notwithstanding sub-clause (i) above: 

  

	 	(A)	except as provided in any individual Senior Debt Instrument with respect to the Senior Creditors under that Senior Debt Instrument, only the following mandatory prepayments shall be applied pro rata across all
Senior Debt, other than any Working Capital Debt (except in the case of sub-clauses (2) and (3) below) and Permitted Senior Debt Hedging Instrument: 

 

	 	(1)	mandatory prepayments with Insurance Proceeds and Condemnation Proceeds as described in, and subject to the requirements of, Section 5.2 (Insurance and Condemnation Proceeds); 

 

	 	(2)	a mandatory prepayment triggered by an LNG SPA Prepayment Event as described in, and subject to the requirements of, Section 3.4(a)(iv) (Mandatory Prepayments – LNG SPA Payment Events) and
Section 8.2 (LNG SPA Mandatory Prepayment) of the Common Terms Agreement (and any comparable provision in any other Senior Debt Instrument then in effect); or 

 

	 	(3)	a mandatory prepayment pursuant to a mandatory prepayment offer following the occurrence of a Change of Control; 

  

	 	(B)	no pro rata prepayment of Senior Notes is required to be made in the event that any Loans are voluntarily paid in accordance with the terms of the applicable Senior Debt Instrument (including, to the extent
applicable, Section 3.5 (Voluntary Prepayments) of the Common Terms Agreement and any comparable provision in any other Senior Debt Instrument then in effect with respect to Loans); 

 

	 	(C)	 no pro rata prepayment of any Senior Debt is required to be made in the event that any voluntary or
optional prepayment of Senior Debt under an individual Senior Debt Instrument or Permitted Hedging Instrument is made to only certain affected Senior Creditors thereunder or only Senior Creditors under such affected Senior Debt Instruments or
Permitted Hedging Instruments as a result of the applicability of yield protection provisions, increased cost provisions or additional amounts relating to Taxes, Defaulting Lender, Non-Consenting Lender or
similar provisions, including, in each case, such provisions as described in Section 3.2 (Right of  

  
 -5- 

 § 2.3(b) 

 

	 	
Repayment and Cancellation in Relation to a Single Facility Lender) or Section 19.5 (Mitigation Obligations; Replacement of Lenders) of the Common Terms Agreement and any
comparable provision of any other Senior Debt Instrument or Permitted Senior Debt Hedging Instrument then in effect; provided that such prepayment is made using (x) the proceeds of Replacement Senior Debt or (y) cash available at
the ninth level of the cash waterfall in accordance with Section 4.7(a)(ix) (Cash Waterfall); 

  

	 	(D)	each of the payments of Breakage Costs and other similar amounts required to be paid pursuant to an individual Senior Debt Instrument only (as referred to in Section 3.6 (Prepayment Fees and Breakage Costs)
of the Common Terms Agreement and any comparable provision of any other Senior Debt Instrument then in effect) and including any cash collateralization of letters of credit required pursuant to the terms of any Working Capital Debt shall not be
required to be made as a Pro Rata Payment; and 

  

	 	(E)	any other payments or prepayments to a Senior Creditor in respect of which it waives its right to a Pro Rata Payment under its Senior Debt Instrument (including, in respect of Facility Lenders, the proviso to
Section 3.7 (Pro Rata Payment) of the Common Terms Agreement (and any comparable provision in any other Senior Debt Instrument then in effect)) which waiver shall be deemed to be a waiver of its right to receive a Pro Rata Payment in
accordance with this Section 2.3(a) (Payments and Prepayments – Pro Rata Payment of Senior Debt Obligations) as a result of which such Senior Creditor shall not require a Pro Rata Payment or prepayment to such Senior
Creditor. 

  

	 	(b)	Sharing of Non-Pro Rata Payments 

  

	 	(i)	Except to the extent no Pro Rata Payment is required under sub-clause (a)(ii) (Pro Rata Payment of Senior Debt Obligations) above and as set out in
sub-clause (ii) below, if any Senior Creditor receives any payment, whether pursuant to enforcement of any Security Interest, as payment of Senior Debt Obligations following acceleration, through right of
set-off or voluntary or involuntary prepayment or otherwise, other than a Pro Rata Payment made pursuant to the Finance Documents, such Senior Creditor shall promptly notify the Company and the Security
Trustee and pay an amount equal to such amount to the Security Trustee for distribution in accordance with this Agreement. 

  
 -6- 

 § 2.3(c) 
  

	 	(ii)	The following amounts shall not be subject to sharing pursuant to sub-clause (i) above: 

 

	 	(A)	any payment made to a Secured Party as indemnity or reimbursement for any additional funding cost, tax incurred or withheld or cost, liability or claim that is the subject of any indemnity, reimbursement or gross-up provision contained in any Finance Document; 

  

	 	(B)	any payment of any fee or premium required by the terms of a Finance Document and not required by the terms of any other Finance Document to be shared; 

 

	 	(C)	any payment of a Permitted Senior Debt Hedging Liability to a Hedging Bank made in accordance with Section 4.7 (Cash Waterfall) or Section 4.8 (Accounts During the Continuance of a Declared Event of
Default), as applicable; and 

  

	 	(D)	any payment representing capitalized interest in respect of any Finance Document. 

 For the
avoidance of doubt, any sub-participation arrangement, credit default swap arrangement, credit derivative transaction, synthetic securitization transaction, insurance arrangement (including any political risk
insurance arrangement) or any other type of back-to-back arrangement entered into in connection with a Senior Creditor’s or Senior Creditor Group’s Senior Debt
(other than any such back-to-back arrangement entered into with the Company or any of its Affiliates (directly or indirectly) resulting in an obligation to make a
payment that relates to a Senior Debt Obligation) shall not be subject to sharing pursuant to sub-clause (i) above. 
  

	 	(c)	Manner of Payment 

 All payments to any Secured Party under any Finance Document shall
be made in accordance with the terms of the relevant Finance Document or, in the absence of any express provisions in that Finance Document, in US Dollars, in immediately available funds, without set-off or
counterclaim and for value on the due date. 
  

	 	(d)	Partial Payments 

 Except as otherwise provided in the relevant Senior Debt Instrument
or Permitted Senior Debt Hedging Instrument, if at any time at which any Senior Debt Obligations are payable to a Senior Creditor, such Senior Creditor (or the Security Trustee or Senior Creditor Group Representative on behalf of such Senior
Creditor) receives insufficient funds to discharge all the amounts then due and payable to such Senior Creditor under the relevant Senior Debt Instrument or Permitted Senior Debt Hedging Instrument, that payment shall be applied towards the Senior
Debt Obligations owed to that Senior Creditor in the following order: 

  
 -7- 

 § 2.3(e) 

 

	 	(i)	first, in or toward payment of any unpaid costs, fees, expenses and all amounts (other than principal, interest, premia (if any) and Breakage Costs on the Senior Debt) payable to that Senior Creditor (including
any such costs, fees or expenses of such Senior Creditor in its capacity as the Security Trustee, Intercreditor Agent, Account Bank, Indenture Trustee or Senior Creditor Group Representative); 

 

	 	(ii)	second, in or toward payment of any post-Event of Default interest on Senior Debt provided by that Senior Creditor and due but unpaid; 

 

	 	(iii)	third, in or toward payment of any other interest on the Senior Debt provided by that Senior Creditor and due but unpaid; 

  

	 	(iv)	fourth, in or toward payment of any principal due but unpaid in respect of Senior Debt provided by that Senior Creditor; and 

  

	 	(v)	fifth, in or toward payment of any other Senior Debt Obligations owed to that Senior Creditor. 

  

	 	(e)	Late Payments 

 Except as otherwise provided in the relevant provisions of the Senior
Debt Instruments (including, to the extent applicable, Section 3.9 (Late Payments) of the Common Terms Agreement and any comparable provision in any other Senior Debt Instrument then in effect) or Permitted Senior Debt Hedging
Instruments, any payment to a Secured Party that is not paid when due under any Finance Document shall be subject to payment of interest at the Default Rate calculated from the date such payment was due to the date such payment is unconditionally
and irrevocably paid in full. 
  

	 	(f)	Payment of Permitted Senior Debt Hedging Liabilities 

 Each payment of Senior Debt
Obligations under a Permitted Senior Debt Hedging Instrument shall be made in accordance with Section 4.7 (Cash Waterfall) or Section 4.8 (Accounts During the Continuance of a Declared Event of Default), as applicable. 

 

	 	2.4	Initial Senior Creditor Group Representative; Replacement or Appointment of Senior Creditor Group Representative 

  

	 	(a)	Each of the Senior Creditor Group Representatives party hereto on the date hereof or pursuant to an accession hereto (other than any Hedging Banks and any other Senior Creditor which is its own Senior Creditor Group
Representative) represents that it has been duly appointed pursuant to the relevant Senior Debt Instrument to represent the relevant Senior Creditor Group and is entitled to vote and give instructions to the Security Trustee on behalf of the Senior
Creditor(s) comprising such Senior Creditor Group. 

  
 -8- 

 § 2.4(c)(i) 

 

	 	(b)	Each Hedging Bank (if any), and each other Senior Creditor which is its own Senior Creditor Group Representative (if any), confirms that it is its own Senior Creditor Group Representative. 

 

	 	(c)	Any Senior Creditor Group Representative may be replaced or appointed by a Senior Creditor Group as provided in the relevant Senior Debt Instrument or Permitted Senior Debt Hedging Instrument, as applicable, and the
Company, the Security Trustee, the Account Bank, the Intercreditor Agent and each other Senior Creditor Group Representative shall be notified promptly of any such replacement or appointment, which shall become effective only: 

 

	 	(i)	in the case of a replacement Senior Creditor Group Representative, upon (A) the replacement Senior Creditor Group Representative evidencing its incumbency to the reasonable satisfaction of the Security Trustee and
acceding to this Agreement as a Senior Creditor Group Representative (and, if the Senior Creditor Group Representative it is replacing was party to the Intercreditor Agreement, to the Intercreditor Agreement) in accordance with Section 2.7
(Accession of Senior Creditor Group Representatives) or, if such entity was party to any Accession Agreement, agreeing in writing to be bound by the Accession Agreement to which its predecessor Senior Creditor Group Representative was a
party; and (B) the Senior Creditor Group Representative being replaced delivering its signature of acknowledgment to the Accession Agreement entered into by the replacement Senior Creditor Group Representative, which signature of acknowledgment
shall be deemed to constitute the resignation of such Senior Creditor Group Representative being replaced; and 

  

	 	(ii)	in the case of a newly appointed Senior Creditor Group Representative, upon the appointed Senior Creditor Group Representative acceding to this Agreement (and, if the Senior Creditor Group Representative represents any
Facility Lender or represents itself as a Hedging Bank, the Intercreditor Agreement) in accordance with Section 2.7 (Accession of Senior Creditor Group Representatives). 

 

	 	(d)	Unless otherwise expressly provided herein, each reference in this Agreement to a Senior Creditor Group Representative shall be understood to be a reference to that Senior Creditor Group Representative acting on behalf
of and for the benefit of the Senior Creditor(s) that have appointed such Senior Creditor Group Representative. 

  

	 	2.5	Other Intercreditor Agents 

  

	 	(a)	Subject to clauses (c) and (d) below, at any time, and from time to time, any group of Senior Creditor Group Representatives may notify the Company, the Security Trustee, the Account Bank, the Intercreditor Agent
and each other Senior Creditor Group Representative in writing that such Senior Creditor Group Representatives have appointed an intercreditor agent to act on their behalf under this Agreement. Such notice shall specify the effective date upon which
such appointment shall take effect. 

  
 -9- 

 § 2.5(b)(i) 

 

	 	(b)	With respect to Senior Creditor Group Representatives who have appointed an intercreditor agent to act on their behalf (prior to any termination or replacement of such intercreditor agent in accordance with clause
(e) below): 

  

	 	(i)	the Company, the Security Trustee, the Account Bank, the Intercreditor Agent and each other Senior Creditor Group Representative shall regard and be entitled to rely upon any statements, directions or notices from such
intercreditor agent in its appointed capacity as if such statements or notices were delivered by the Senior Creditor Group Representatives that have appointed such intercreditor agent and shall be entitled to regard delivery of any statements or
notices to such intercreditor agent as delivery of such statements or notices to the appointing Senior Creditor Group Representatives; and 

  

	 	(ii)	any provisions herein that refer to the approval of, or notice, direction or statement from or to, any such appointing Senior Creditor Group Representative shall be deemed to be references to the approval of, or notice,
direction or statement from or to, the intercreditor agent acting on behalf of such Senior Creditor Group Representative (for the benefit of the relevant Senior Creditors). 

 

	 	(c)	Each Senior Creditor Group Representative party hereto on the date hereof or pursuant to an accession hereto (other than any Indenture Trustee) has appointed the Intercreditor Agent pursuant to the Intercreditor
Agreement to act as its representative for all matters under this Agreement. For the avoidance of doubt, the Intercreditor Agent does not represent or act for any Indenture Trustee or any Senior Creditor Group Representative that may be appointed
from time to time for any Senior Noteholders. 

  

	 	(d)	For so long as the Intercreditor Agreement is effective, no Senior Creditor Group Representative representing any Facility Lender or representing itself as a Hedging Bank nor the Facility Lenders nor any Hedging Bank
shall appoint any other intercreditor agent pursuant to this Section 2.5 (Other Intercreditor Agents). For the avoidance of doubt, the Intercreditor Agent represents and may act for all Senior Creditor Group Representatives
representing Facility Lenders and/or Hedging Banks and all Facility Lenders and/or Hedging Banks represented by such Senior Creditor Group Representatives. 

  

	 	(e)	At any time and from time to time, any Senior Creditor Group Representatives that have appointed an intercreditor agent pursuant to this Section 2.5 (Other Intercreditor Agents) may:

  

	 	(i)	terminate the appointment of such intercreditor agent; and/or 

  

	 	(ii)	replace such intercreditor agent, 

  
 -10- 

 § 0 
  

 in each case in accordance with the terms of its intercreditor agreement and by written
notice from such Senior Creditor Group Representatives to the Company, the Security Trustee, the Account Bank, the Intercreditor Agent and each other Senior Creditor Group Representative. 

 

	 	2.6	Transfers and Holders of Senior Debt Obligations 

  

	 	(a)	For the avoidance of doubt, no participant, beneficial owner or other Person who is not in each case a Holder pursuant to a Senior Debt Instrument or Permitted Senior Debt Hedging Instrument shall have or acquire rights
greater than those of the Senior Creditor through which it owns its indirect interest in the Senior Debt Obligations, and, accordingly, all such participants, beneficial owners and other Persons having an indirect interest in Senior Debt Obligations
shall be subject to the terms and conditions hereof, notwithstanding that they are not Senior Creditors. 

  

	 	(b)	Each Senior Debt Obligation may be sold, exchanged, traded, assigned, novated or otherwise transferred (subject, to the extent applicable, to the Intercreditor Agreement) as provided in the related Senior Debt
Instrument or Permitted Senior Debt Hedging Instrument, and any Person becoming a Holder thereof from time to time in accordance with such Senior Debt Instrument or Permitted Senior Debt Hedging Instrument shall be deemed to be a Senior Creditor,
and each Person ceasing to be a Holder thereof from time to time in accordance with such Senior Debt Instrument or Permitted Senior Debt Hedging Instrument shall cease to be a Senior Creditor. 

 

	 	2.7	Accession of Senior Creditor Group Representatives 

  

	 	(a)	Any Senior Creditor Group that provides Additional Senior Debt pursuant to Section 2.2 (Incremental Senior Debt) or any Senior Creditor that enters into a Permitted Senior Debt Hedging Instrument pursuant to
Section 2.2 (Incremental Senior Debt) shall appoint a Senior Creditor Group Representative (or may act as its own Senior Creditor Group Representative) that shall enter into an Accession Agreement (on behalf of such Senior Creditor Group
or itself) in accordance with the provisions hereof. 

  

	 	(b)	 Each Accession Agreement entered into pursuant to this Section 2.7 (Accession of Senior Creditor Group
Representatives) shall be substantially in the form of Schedule D-1 (Forms of Accession Agreements – Form of Senior Creditor Group Representative Accession Agreement) in which, among the
other provisions set forth in such form, the relevant Senior Creditor Group Representative agrees to become a party to this Agreement and to be bound by all of the terms and conditions of this Agreement (including the pari passu
ranking of all Senior Debt Obligations set forth in Section 3.1 (Pro Rata First-Ranking Security Interests)) and, if the Senior Creditor Group Representative represents any Facility Lender or represents itself as a Hedging Bank, to be
bound by all of the terms and conditions of the Intercreditor Agreement. Each and every agreement expressed to be made herein 

  
 -11- 

 § 2.7(b) 

 

 
by a Senior Creditor is made hereunder (and with respect to a Senior Creditor Group Representative that represents any Facility Lender or represents itself as a Hedging Bank, each and every
agreement expressed to be made in the Intercreditor Agreement shall be made thereunder) by the relevant Senior Creditor Group Representative on behalf of each such Senior Creditor it represents, and each Accession Agreement entered into by a Senior
Creditor Group Representative representing any Senior Creditor other than itself shall contain a representation that the related Senior Debt Instrument authorizes such Senior Creditor Group Representative to make such agreements on behalf of the
relevant Senior Creditor(s). 
  

	 	(c)	No replacement or newly appointed Senior Creditor Group Representative shall become a Senior Creditor Group Representative under this Agreement or the Intercreditor Agreement unless and until: 

 

	 	(i)	an Accession Agreement meeting the requirements of this Section 2.7 (Accession of Senior Creditor Group Representatives) shall have been executed and delivered to the Security Trustee; 

 

	 	(ii)	such Accession Agreement, when delivered to the Security Trustee, shall be accompanied by one or more certificates as to the due authorization, execution and delivery of the Accession Agreement and incumbency of the
officers or attorneys-in-fact of the new Senior Creditor Group Representative who executed the Accession Agreement and shall include notice details for the new Senior
Creditor Group Representative; 

  

	 	(iii)	in the case of a Senior Creditor Group Representative appointed by a Senior Creditor Group that provides Initial Senior Debt or Additional Senior Debt, the applicable Senior Debt Instrument(s) shall have been entered
into with the Company; 

  

	 	(iv)	in the case of a Hedging Bank representing itself as a Senior Creditor Group Representative, such Hedging Bank shall have entered into its Permitted Senior Debt Hedging Instrument with the Company; and

  

	 	(v)	the Security Trustee has received any documentation reasonably requested by it in order for it to carry out all necessary “know your customer” or similar requirements with respect to the new Senior Creditor
Group Representative, including those reasonably required to ensure compliance with anti-money laundering procedures in its relevant jurisdiction. 

  

	 	(d)	Fully executed copies of the related Senior Debt Instruments or Permitted Senior Debt Hedging Instruments, as applicable, shall be attached to the Accession Agreement as exhibits and each Accession Agreement shall
specify in an exhibit thereto: 

  
 -12- 

 § 2.7(d)(i) 

 

	 	(i)	the identity of the related Senior Creditors (which need not include the Holders of notes or other securities or term loans issued pursuant to an Indenture); 

 

	 	(ii)	the related Senior Debt Commitments (if applicable); and 

  

	 	(iii)	the related Senior Debt Instruments or Permitted Senior Debt Hedging Instruments. 

  

	 	(e)	The Security Trustee shall, as soon as reasonably practicable, after receiving a duly completed Accession Agreement which appears on its face to comply with the terms of this Section 2.7 (Accession of Senior
Creditor Group Representatives): 

  

	 	(i)	countersign such Accession Agreement by way of acceptance thereof; 

  

	 	(ii)	amend Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and
Facility Lenders Facility Office) hereto accordingly; and 

  

	 	(iii)	deliver the revised Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses
for Notice and Facility Lenders Facility Office) to the Intercreditor Agent, the Company, the Account Bank and each Senior Creditor Group Representative. 

  

	 	(f)	Upon the later of: 

  

	 	(i)	the date defined in the Accession Agreement as its effective date; and 

  

	 	(ii)	the date on which the Security Trustee countersigns the Accession Agreement by way of acceptance thereof (as contemplated in sub-clause (e)(i) above), 

the Senior Creditor Group Representative shall become (if not already) a party to this Agreement (and, if the Senior Creditor Group
Representative represents any Facility Lender or represents itself as a Hedging Bank, the Intercreditor Agreement) and, if applicable and subject to the terms of Section 2.2 (Incremental Senior Debt), the providers of Additional Senior
Debt or the Hedging Bank, as applicable, represented by such Senior Creditor Group Representative shall become Senior Creditors and such debt obligations provided by them shall become Senior Debt Obligations. 

 

	 	2.8	Changes to Senior Debt Instruments and Permitted Senior Debt Hedging Instruments 

  

	 	(a)	Each Senior Creditor Group Representative shall notify, as soon as reasonably practicable, the Security Trustee, the Account Bank and each other Senior Creditor Group Representative of any proposed amendment,
modification or other change to or under its related Senior Debt Instrument(s) or Permitted Senior Debt Hedging Instrument(s). 

  
 -13- 

 § 0 
  

	 	(b)	No such amendment, modification or other change shall be permitted or recognized for any purpose under this Agreement, any other Security Document or any Direct Agreement, unless it has been adopted and implemented in
compliance with this Agreement in addition to the requirements of any such Senior Debt Instrument, Permitted Senior Debt Hedging Instrument and any Intercreditor Agreement applicable thereto, and no such amendment, modification or other change shall
purport to change, or have the effect of changing, the rights and duties of the Security Trustee or the Account Bank hereunder or under any other Security Document or any Direct Agreement or otherwise modifying the terms and conditions of this
Agreement or any other Security Document or Direct Agreement. 

  

	 	2.9	Discharge of Certain Senior Debt Obligations 

 Subject to Section 10.1 (Nature of
Obligations), upon the occurrence of the Discharge Date with respect to all of the Senior Debt Obligations or with respect to the Senior Debt Obligations under an individual Senior Debt Instrument or Permitted Senior Debt Hedging Instrument, as
the case may be, in each case in accordance with the relevant Senior Debt Instrument or Permitted Senior Debt Hedging Instrument, without further action by the Security Trustee: 

 

	 	(a)	the discharged Senior Debt Obligations thereunder shall no longer constitute Senior Debt Obligations entitled to the benefits hereof and of the other Security Documents and the Direct Agreements; 

 

	 	(b)	the former Senior Creditors thereof shall no longer be Secured Parties; 

  

	 	(c)	the related Senior Debt Instruments or Permitted Senior Debt Hedging Instruments shall no longer be Senior Debt Instruments or Permitted Senior Debt Hedging Instruments; provided that there are no Senior
Creditors who are parties thereto with outstanding Senior Debt Commitments or to whom Senior Debt Obligations are owed pursuant to such Senior Debt Instruments or Permitted Senior Debt Hedging Instruments; and 

 

	 	(d)	such related Senior Creditor Group Representative(s) shall no longer be a party hereto in such capacity. 

The relevant Senior Creditor Group Representative shall deliver to the Security Trustee a certificate stating that the Discharge Date in
respect of all such Senior Debt Obligations shall have occurred. 
 Any such former Senior Creditor Group Representative in its own capacity
(and on behalf of the relevant former Senior Creditors) shall cooperate with the Security Trustee, at the expense of the Securing Parties, to make all modifications and amendments to the Security Documents or execute and deliver any notice,
termination statement, financing statement, continuation statement, public deed, instrument, document or agreement as may be reasonably necessary or that may be reasonably requested by the Security Trustee (and the Company may reasonably request the
Security Trustee to make such a request) to create, preserve, continue, perfect or validate the Security Interests for the benefit of any remaining Secured Parties. 

  
 -14- 

 § 2.10 
  

	 	2.10	Sponsor and its Affiliates 

 None of the Sponsor nor any of its Affiliates other than the
Securing Parties is a party hereto or to any Security Document as a grantor of any Security Interest contemplated hereby, except that Holdco will be party to and grantor under only such of the Security Documents necessary to create and perfect the
Security Interests referred to in Section 3.3 (Security Interests to be Granted by Holdco). Anything herein that purports to bind or obligate Holdco shall be construed as an agreement by the Company to procure that Holdco shall take the
required action. 
  

	 	2.11	Secured Party Guarantees 

 Notwithstanding any other provision contained herein or in any
other Finance Document, including without limitation Section 12.15 (Guarantees) of the Common Terms Agreement and Section 4.25 (Limitation on Guarantees) of the Indenture, a Securing Party may guarantee any obligations of any
other Securing Party that such other Securing Party is permitted to incur under the Finance Documents. 
  

	3.	SECURITY INTERESTS 

  

	 	3.1	Pro Rata First-Ranking Security Interests 

  

	 	(a)	Except as expressly provided in Section 3.2(c) (Security Interests to be Granted by the Securing Parties – Security Interests – Individual Senior Noteholder Secured Accounts), all Security
Interests created hereunder, or under the Security Documents, are a common security package for the benefit of the Secured Parties, ranking in right of payment and upon enforcement pari passu with each other without priority or preference by reason
of date of incurrence, currency of payment or otherwise. The Security Interests shall be first-ranking or first priority security interests, subject only to any Permitted Liens to the extent specified herein, and all references in the Finance
Documents to “first ranking” or “first priority” shall be construed accordingly. The Security Interests shall be realized in accordance with the terms and priorities set forth herein, including Section 6.7 (Enforcement
Proceeds Account). 

  

	 	(b)	Each reference in this Article 3 (Security Interests) to the Security Trustee shall be understood to be a reference to the Security Trustee acting for the benefit of the Secured Parties, unless otherwise
explicitly specified. 

  
 -15- 

 § 3.2(a)(ii) 

 

	 	3.2	Security Interests to be Granted by the Securing Parties 

  

	 	(a)	Pledge of Pledged Collateral 

 As security for the payment in full in US Dollars or the
performance in full, as the case may be, of the Senior Debt Obligations, each Securing Party hereby collaterally assigns, pledges and grants to the Security Trustee, for the ratable benefit of the Secured Parties, a first ranking (subject to
Permitted Liens in clause (a) thereof) and continuing Lien on, all of such Securing Party’s right, title and interest whether now owned or hereafter existing or acquired in, to and under any and all of the following, except to the extent
falling under clause (g) (Excluded Assets) below (all of the property and assets described in this clause (a) other than Excluded Assets being hereinafter collectively referred to herein as the “Pledged Collateral”):

  

	 	(i)	the Guarantor Interests, including all such Securing Party’s capital or ownership interest (including capital accounts), in any Guarantor owned by such Securing Party on the date hereof (collectively referred to
herein as the “Pledged Equity Interests”); 

  

	 	(ii)	all rights to receive income, gain, profit, all shares, securities, membership or partnership interests, moneys or property representing a dividend, and other distributions or return of capital allocated or distributed
to such Securing Party in respect of, or resulting from a split up, revision, reclassification or other like change of or otherwise in exchange for all or any portion of the Pledged Equity Interests; 

 

	 	(iii)	all of such Securing Party’s voting rights in, or rights to control or direct the affairs of, any Guarantor owned by such Securing Party; 

 

	 	(iv)	all other rights, title and interest in or to any Guarantor derived from the Pledged Equity Interests (including all rights of such Securing Party as a member of such Guarantor under the Constitutional Documents of such
Guarantor); 

  

	 	(v)	without affecting the obligations of such Securing Party or any Guarantor owned by such Securing Party under any provision prohibiting that action under any Finance Document, in the event of any consolidation or merger
of such Guarantor in which such Guarantor is not the surviving entity, (A) all shares, securities, membership, partnership or ownership interests, as applicable, of any successor entity formed by or resulting from that consolidation or merger,
including all rights, title, claims or interests associated therewith, if such shares, securities, membership, partnership or ownership interests are owned by such Securing Party after such consolidation or merger and (B) all other
consideration (including all personal property, tangible or intangible) received by the Securing Party for such Collateral; 

  

	 	(vi)	all rights of such Securing Party to terminate, amend, supplement, modify, or cancel the Constitutional Documents of any Guarantor, to take all actions thereunder and to compel performance and otherwise exercise all
remedies thereunder; 

  
 -16- 

 § 3.2(a)(ix) 

 

	 	(vii)	(A) the debt securities or Indebtedness (including intercompany Indebtedness) held by such Securing Party on the date hereof or Indebtedness represented by an instrument or other transferable document and (B) any
debt securities or indebtedness (including intercompany Indebtedness) in the future issued to or held by such Securing Party (collectively, the “Pledged Debt Securities”); 

 

	 	(viii)	all payments of principal or interest, dividends, cash, instruments and other property from time to time received, receivable or otherwise distributed in respect of, in exchange for or upon the conversion of, and all
other Proceeds received in respect of the Pledged Equity Interests and the Pledged Debt Securities, as applicable; 

  

	 	(ix)	all rights and privileges of such Securing Party with respect to the securities and other property referred to above, as applicable; 

 

	 	(x)	all notes (including promissory notes), certificates and other instruments representing or evidencing any of the foregoing rights and interests, debt securities, indebtedness or the ownership thereof from time to time
received, receivable or otherwise distributed in respect of or in exchange for any or all of such rights and interests; and 

  

	 	(xi)	all proceeds, products and accessions (including “proceeds” as defined in Section 9-102(a)(64) of the UCC) and all causes of action, claims and warranties now or
hereafter held by such Securing Party, in respect of any of the items listed above, of and to the foregoing Collateral, whether cash or non-cash and, to the extent related to any property described in said
clauses or such proceeds, all books, correspondence, credit files, records, invoices and other papers, including all tapes, cards, computer runs, programs, printouts, databases and other computer materials, and documents in the possession or under
the control of such Securing Party. 

  

	 	(b)	Security Interests – General 

 As security for the payment in full in US
Dollars or the performance in full, as the case may be, of the Senior Debt Obligations, each Securing Party hereby assigns, transfers and grants to the Security Trustee, for the ratable benefit of the Secured Parties, a first-ranking (subject only
to Permitted Liens) and continuing Lien on all of such Securing Party’s right, title and interest in, to and under all personal property of such Securing Party (except to the extent falling within the assets described in clause (g) (Excluded
Assets) below). Such security interests shall be included in the Common Collateral, including the following, other than Excluded Assets, in each case whether now or hereafter existing or in which the applicable Securing Party now has or
hereafter acquires an interest and wherever the same may be located: 

  
 -17- 

 § 3.2(b)(i)(D) 

 

	 	(i)	all contracts, agreements and documents, including the following contracts, agreements and documents, as amended, amended and restated, supplemented, replaced, renewed or otherwise modified from time to time
(individually, an “Assigned Agreement” and collectively, the “Assigned Agreements”) and all of each Securing Party’s rights thereunder: 

 

	 	(A)	the Material Project Agreements; 

  

	 	(B)	the Permitted Hedging Instruments; 

  

	 	(C)	the insurance policies maintained or required to be maintained by or for the benefit of any Securing Party under any Finance Document or any Material Project Agreement, including any such policies insuring against loss
of revenues by reason of interruption of the operation of the Project Facilities and all proceeds and other amounts payable to any Securing Party thereunder, and all proceeds from any taking or condemnation; 

 

	 	(D)	all other agreements (including vendor warranties and guaranties and performance bonds, sureties and security), running to any Securing Party or assigned to any Securing Party, relating to the construction, maintenance,
improvement, operation or acquisition of the Project Facilities or any part thereof, or transport of material, equipment and other parts of the Development or any part thereof; 

 

	 	(E)	any and all other agreements to which any Securing Party may be a party relating to the construction or operation of the Project Facilities or any part thereof; and 

 

	 	(F)	as regards the aforesaid agreements, (1) all rights of any Securing Party to receive moneys due and to become due thereunder or pursuant thereto, (2) all rights of any Securing Party to receive proceeds of any
insurance, indemnity, warranty or guaranty with respect thereto, (3) all claims of any Securing Party for damages for breach thereof or default thereunder, (4) all rights of any Securing Party to perform thereunder and to compel
performance or otherwise exercise all remedies thereunder, (5) all rights of any Securing Party to terminate, amend, supplement, or otherwise modify any such agreement or approval, and (6) all rights of any Securing Party under each such
contract or agreement to make determinations, to exercise any election or option or to give or receive any notice, consent, waiver, or approval, together with full power and authority with respect to any contract or agreement to demand, receive,
enforce, collect or provide receipt for any of the foregoing rights or any property the subject of any of the contracts or agreements, to enforce or execute any checks, or other instruments or orders, to file any claims and to take any action which
may be necessary or advisable in connection with any of the foregoing; 

  
 -18- 

 § 3.2(b)(iii) 

 

	 	(ii)	all Securities Accounts and Deposit Accounts (in each case that are not Individual Senior Noteholder Secured Accounts or Excluded Unsecured Accounts), and any sub-accounts
established therein, in each case together with all funds, cash, monies, Financial Assets, investments, instruments, certificates of deposit, promissory notes, and any other property (including any Authorized Investments and other permitted
investments deposited therein or credited thereto) at any time on deposit therein or credited to any of the foregoing, all rights to payment or withdrawal therefrom, and all income, profits, gains, and interest thereon; 

 

	 	(iii)	all escrow accounts established under the EPC Contracts; 

  

	 	(iv)	all Instruments; 

  

	 	(v)	all Documents; 

  

	 	(vi)	all Chattel Paper (whether tangible or electronic); 

  

	 	(vii)	all Inventory; 

  

	 	(viii)	all Equipment; 

  

	 	(ix)	all Fixtures, wherever located and whenever acquired, whether or not of a type which may be subject to a security interest under the UCC, including all machinery, tools, engines, appliances, mechanical and electrical
systems, elevators, lighting, alarm systems, fire control systems, furnishings, furniture, service equipment, building or maintenance equipment, building or maintenance materials, supplies, goods and property covered by any warehouse receipts or
bills of lading or other such documents, spare parts, maps, plans, specifications, architectural, engineering, construction or shop drawings, soil tests, appraisals, route surveys, engineering reports, manuals and similar documents relating to all
or any portion of the Project Facilities and the Development, and any replacements, renewals or substitutions for any of the foregoing or additional tangible or intangible personal property hereafter acquired by any Securing Party;

  

	 	(x)	all Supplies and Raw Materials; 

  

	 	(xi)	all Intellectual Property; 

  

	 	(xii)	all Rolling Stock (if any); 

  

	 	(xiii)	all Goods not covered by the preceding sub-clauses of this Section 3.2(b) (Security Interests – General); 

  
 -19- 

 § 3.2(b)(xiv) 

 

	 	(xiv)	all Letter-of-Credit Rights; 

  

	 	(xv)	all Investment Property; 

  

	 	(xvi)	all Payment Intangibles, Software and all other General Intangibles whatsoever not covered elsewhere in this Section 3.2(b) (Security Interests – General); 

 

	 	(xvii)	all rights and claims of any Securing Party, now or hereafter existing, under any indemnity, warranty or guaranty in connection with any Equipment; 

 

	 	(xviii)	all Receivables, As-extracted Collateral, Commodity Accounts, Money and Records; 

  

	 	(xix)	all Commercial Tort Claims described in Schedule E (Commercial Tort Claims) hereto and on any supplement thereto received by the Security Trustee pursuant to Section 3.5(h) (Perfection and
Maintenance of Security Interests); 

  

	 	(xx)	all Collateral Records; 

  

	 	(xxi)	to the extent not otherwise included above, all other tangible and intangible personal property of the Securing Parties and all accessions, rents and profits of any and all of the foregoing and all collateral security,
Supporting Obligations and guarantees given by any Person with respect to any of the foregoing; and 

  

	 	(xxii)	 to the extent not otherwise included in the foregoing, all Proceeds and products of any of the foregoing
Collateral, whether cash or non-cash, including (A) all rights of any Securing Party to receive moneys due and to become due under or pursuant to such Securing Party’s ownership and operation of the
Project Facilities or any part thereof or otherwise related to the Collateral, (B) all rights of any Securing Party to receive return of any premiums for or proceeds of any insurance, indemnity, warranty or guaranty with respect to the
Collateral described in this Section 3.2(b) (Security Interests – General) or to receive condemnation proceeds, (C) all claims of any Securing Party for damages arising out of or for breach of or default under any of the
Assigned Agreements or any other Collateral described in this Section 3.2(b) (Security Interests – General), (D) all rights of any Securing Party to payment for goods or other property sold or leased or services performed by
such Securing Party, (E) to the extent not included in the foregoing, all proceeds receivable or received when any and all of the foregoing Collateral is sold, collected, exchanged or otherwise disposed of, whether voluntarily or involuntarily,
and (F) any and all additions and accessions to the Collateral, and all proceeds thereof, including proceeds of the conversion, voluntary or involuntary, of any of the foregoing into cash or liquidated claims, including all awards, all

  
 -20- 

 § 3.2(c) 

 

	 	
insurance proceeds, including any unearned premiums or refunds of premiums on any insurance policies covering all or any part of the Collateral and the right to receive and apply the proceeds of
any insurance, or of any judgments or settlements made in lieu thereof for damage to or diminution of the Collateral. 

  

	 	(c)	Security Interests – Individual Senior Noteholder Secured Accounts 

 The
Company hereby assigns and transfers to, and grants to the Security Trustee, for the benefit solely of the applicable Senior Noteholders: 
  

	 	(i)	as security for the Senior Debt Obligations (whether at stated maturity, by acceleration or otherwise) under Senior Notes of any series that is entitled to the proceeds of any mandatory prepayment that have been
deposited into a Mandatory Prepayment Senior Notes Account, a first-ranking security interest in such Mandatory Prepayment Senior Notes Account, and all cash, Financial Assets or other property now or hereafter credited thereto or held therein, and
investments (including Authorized Investments) made with or arising out of such funds and all Proceeds of the foregoing; and 

  

	 	(ii)	who purchase Senior Notes pursuant to Section 4.5(a)(iii) (Deposits and Withdrawals – Disbursements of Senior Debt – Disbursements of Senior Debt – Escrow of
Senior Notes Issued as Replacement Senior Debt), a first-ranking security interest in the proceeds of such Senior Notes and investments (including Authorized Investments) made with or arising out of such funds that are held in escrow in a Senior
Note Disbursement Account, 

 (the Accounts in sub-clauses (i) and (ii) above,
the “Individual Senior Noteholder Secured Accounts”). 
  

	 	(d)	Provisions Related to Secured Accounts 

  

	 	(i)	All funds and other property delivered for credit to any Account shall be held by the Account Bank and promptly credited to an Account by an appropriate entry in its records in accordance with this Agreement.

  

	 	(ii)	To the knowledge of the Account Bank, on the date hereof, there is no Lien on any of the Accounts other than Permitted Liens and the claims and interest of the parties as provided herein. In the event that the Account
Bank has or subsequently obtains by agreement, operation of Government Rule or otherwise a security interest in any Account or any security entitlement credited thereto other than Permitted Liens, the Account Bank hereby agrees that such security
interest shall be fully subordinated in payment and with respect to any right to exercise remedies to the security interest of the Security Trustee for the benefit of the Secured Parties. 

  
 -21- 

 § 3.2(d)(iii) 

 

	 	(iii)	On the date hereof, the Account Bank has no notice of any adverse claim to the “financial assets” (within the meaning of Section 8-102(a)(9) of the UCC and
including cash) deposited in or credited to the various Accounts or to security entitlements with respect thereto other than Permitted Liens and the claims and interest of the parties as provided herein. If any Person asserts any Lien (including any
writ, garnishment, judgment, warrant of attachment, execution or similar process, but excluding any Permitted Liens and the claims and interest of the parties as provided herein) against any Account or in any Financial Assets deposited in, or
credited to, the various Accounts or to security entitlements with respect thereto, the Account Bank, upon obtaining actual knowledge thereof, will promptly notify the Security Trustee and the Company thereof. 

 

	 	(iv)	Each Account shall be created and treated by the Account Bank as a Securities Account unless such Account is not considered to be a Securities Account (within the meaning of
Section 8-501(a) of the UCC) under any applicable Government Rule. If such Account is not a Securities Account, the Account shall be created and treated by the Account Bank as a Deposit Account (within
the meaning of Section 9-102(a)(29) of the UCC), which shall be maintained with the Account Bank acting not as a securities intermediary but as a “bank” (within the meaning of Section 9-102(a)(8) of the UCC). The Account Bank shall not have title to the funds on deposit in the Accounts, and shall credit the Accounts with all receipts of interest, dividends and other income received
on the property held in the Accounts. Until this Agreement terminates in accordance with its terms, each of the Company, the Account Bank and the Security Trustee agrees that the Security Trustee shall have sole “control” (within the
meaning of Sections 9-104(a)(2) and (3) of the UCC) of the Accounts. All funds delivered to the Account Bank pursuant to this Agreement will be promptly credited to the Accounts. In furtherance of the
intentions of the parties hereto, this Agreement constitutes written notice by the Security Trustee to the Account Bank of the Security Trustee’s Security Interest (for the benefit of the applicable Secured Parties) in the Accounts.

  

	 	(v)	Accounts – Deposit Accounts 

 Solely with respect to any Account that is created
and treated as a Deposit Account, the Company, the Security Trustee and the Account Bank agree that: 
  

	 	(A)	the Account Bank shall be a Bank in respect of such Account; 

  

	 	(B)	the Company shall be the customer (as defined in the UCC) in respect of such Account; 

  

	 	(C)	the Bank’s Jurisdiction for such Account shall be the State of New York; 

  
 -22- 

 § 3.2(d)(v)(F) 

 

	 	(D)	the Security Trustee shall have control (as defined in the UCC) over such Account; 

	 	

	 	(E)	the Account Bank shall not have title to the funds on deposit in such Account, and shall credit such Account with all receipts of interest, dividends and other income received on the property held in such Account;

  

	 	(F)	the Account Bank has not entered into, and agrees that, until the termination of this Agreement in accordance with the terms hereof, it will not enter into, any agreement with any Person in respect of any of the
Accounts pursuant to which it would agree to comply with entitlement orders, other orders or instructions made by such Person (other than this Agreement and any customary agreement required by the Account Bank of the Company in order to open or
manage the Accounts (including the e-banking agreement contemplated by Section 4.4(d) (Procedures for Deposits and Withdrawals from Accounts)), provided that a copy of any such agreement has been
delivered to the Security Trustee (and the Security Trustee shall then deliver a copy to each Senior Creditor Group Representative) and in the event of any conflict between this Agreement and the terms of any such other agreements entered into at
any time and notwithstanding any provision of any other agreement that would purport to resolve any conflict between that agreement and this Agreement in favor of that agreement (including but not limited to Section 6.9 of the Funds Transfer
Agreement, dated as of March 11, 2015, between the Account Bank and the Company (the “Funds Transfer Agreement”)), this Agreement shall prevail); 

 

	 	(G)	the Company hereby irrevocably directs, and the Account Bank hereby agrees that the Account Bank will comply with all instructions regarding such Account originated by the Security Trustee without the further consent of
the Company or any other Person; and 

  

	 	(H)	in the case of any conflict between any instruction or order originated by the Security Trustee and any instruction or order originated by the Company or any other Person, the instruction or order originated by the
Security Trustee shall prevail. 

  
 -23- 

 § 3.2(d)(vi)(B) 

 

	 	(vi)	Accounts – Securities Accounts 

 Solely with respect to any Account that is created
and treated as a Securities Account, the Company, the Security Trustee and the Account Bank agree that: 
  

	 	(A)	the Company shall be the Entitlement Holder in respect of the Financial Assets credited to such Account; 

  

	 	(B)	each item of property (including a Security, Security Entitlement, Investment Property, Instrument or obligation, share, participation, funds, cash, interest or other property whatsoever) credited to such Account shall
to the fullest extent permitted by law be treated as a Financial Asset and the right to it shall constitute a Security Entitlement; 

  

	 	(C)	the Security Trustee shall have control (as defined in the UCC) of such Account and the Company’s Security Entitlements with respect to the Financial Assets credited to such Account; 

 

	 	(D)	the Account Bank has not entered into, and agrees that, until the termination of this Agreement in accordance with the terms hereof, it will not enter into, any agreement with any Person in respect of any of the
Accounts pursuant to which it would agree to comply with entitlement orders, other orders or instructions made by such Person (other than this Agreement and any customary agreement required by the Account Bank of the Company in order to open the
Accounts, provided that a copy of any such agreement has been delivered to the Security Trustee (and the Security Trustee shall then deliver a copy to each Senior Creditor Group Representative) and in the event of any conflict between this Agreement
and the terms of any such other agreements entered into at any time and notwithstanding any provision of any other agreement that would purport to resolve any conflict between that agreement and this Agreement in favor of that agreement (including
but not limited to Section 6.9 of the Funds Transfer Agreement), this Agreement shall prevail); 

  

	 	(E)	the Company hereby irrevocably directs, and the Account Bank (in its capacity as Securities Intermediary) hereby agrees, that the Account Bank will comply with all instructions and orders (including Entitlement Orders)
regarding such Account and any Financial Asset therein originated by the Security Trustee without the further consent of the Company or any other Person; 

  

	 	(F)	in the case of a conflict between any instruction or order originated by the Security Trustee and any instruction or order originated by the Company or any other Person, the instruction or order originated by the
Security Trustee shall prevail; 

  
 -24- 

 § 3.2(d)(vi)(I) 

 

	 	(G)	all Financial Assets or other property in registered form or payable to or to the order of and credited to such Account shall be registered in the name of, payable to or to the order of, or endorsed to, the Security
Trustee or in blank, or credited to another account maintained in the name of the Security Trustee, and in no case will any Financial Assets or other property credited to such Account be registered in the name of, payable to or to the order of, or
endorsed to, the Company (except to the extent the foregoing have been subsequently endorsed by the Company to the Security Trustee or in blank); 

  

	 	(H)	the Account Bank shall be the Securities Intermediary in respect of such Account, and the Securities Intermediary’s Jurisdiction for such Account shall be the State of New York, and the laws of the State of New
York are applicable to all issues specified in Article 2(1) of the Hague Securities Convention; and 

  

	 	(I)	all investments of funds in the Accounts shall be credited to the related Account. 

  

	 	(vii)	The Account Bank, in its capacity as Securities Intermediary or Bank, as applicable: (1) subordinates in favor of each applicable Secured Party any security interest, Lien, or right of recoupment or set-off it may have or subsequently obtains by agreement, operation of Government Rule, or otherwise, now or in the future, against the Accounts and (2) agrees that it will not exercise any right in respect of
such security interest or Lien or any such right of recoupment or set-off for so long as this Agreement remains in effect, except for the amount of any returned items and charge-backs either for uncollected
checks or other items of payment and transfers previously credited to one or more of the Accounts and thereafter returned unpaid or otherwise reversed for any reason, and the Company and the Security Trustee hereby authorize and direct the Account
Bank to debit the Accounts for such amounts. 

  

	 	(viii)	The Security Trustee hereby covenants that, for the benefit of the Company, it will not originate any instruction or order (including Entitlement Orders) regarding any Account, any Financial Asset therein or any other
amounts on deposit therein or credited thereto except as set forth in this Agreement. 

  

	 	(ix)	The Account Bank shall not change the name or account number of any Account without the prior written consent of the Security Trustee and the Company (such consent not to be unreasonably withheld or delayed), except for
changes due to internal system modifications (or other internal reorganization of account numbers by Account Bank), of which the Account Bank shall promptly notify the Company and the Security Trustee. 

  
 -25- 

 § 3.2(f) 

 

	 	(e)	Insurance. To the extent the Securing Parties have in place any Texas-law governed insurance policies and a collateral assignment agreement would be required under
applicable Government Rules to perfect the Security Interest of the Security Trustee therein, except to the extent falling under the assets described in clause (g) (Excluded Assets) below, the Company shall execute and deliver to the Security
Trustee, as security for the Senior Debt Obligations, a collateral assignment agreement, in form and substance reasonably satisfactory to Securing Parties and the Security Trustee, of any such insurance policies then required to be in place under
the relevant provisions of the Senior Debt Instruments (including, to the extent applicable, Section 12.28 (Insurance Covenant) of the Common Terms Agreement and any comparable provision in any other Senior Debt Instrument then in
effect) that are governed by the laws of the State of Texas, which shall be included in the Common Collateral (for the avoidance of doubt, title insurance is excluded from this section). 

 

	 	(f)	Real Property 

  

	 	(i)	By Second Phase Closing, the Company shall deliver the executed amended and restated deeds of trust substantially in the form attached as Schedule I-1 (Form of Amended and
Restated Deed of Trust (CCH and CCL)) and Schedule I-2 (Form of Amended and Restated Deed of Trust (CCP)) (or in form and substance reasonably acceptable to the Security Trustee), and satisfy
each of the applicable requirements set out in Section 4.1(j) (Conditions to Second Phase Closing – Real Property) of the Common Terms Agreement, with respect to all Real Estate of the Securing Parties, together with all documents
and instruments required under the law of the State of Texas to perfect the Security Interest of the Security Trustee in such Common Collateral free of any other pledges, security interests or deeds of trust, except Permitted Liens.

  

	 	(ii)	 The Company shall deliver an executed deed of trust substantially in the applicable form attached as Schedule I-1 (Form of Amended and Restated Deed of Trust (CCH and CCL)) or Schedule I-2 (Form of Amended and Restated Deed of Trust (CCP)) (or in form and
substance reasonably acceptable to the Security Trustee), or otherwise amend an existing deed of trust to include, and to the extent not already satisfied, to satisfy, each of the applicable requirements set out in Section 4.1(j) (Conditions
to Second Phase Closing – Real Property) of the Common Terms Agreement with respect to all Real Estate of the Securing Parties acquired or otherwise established after Second Phase Closing that has a purchase price in excess of $10,000,000
or is otherwise material to the operation of the Development within 60 days of such 

  
 -26- 

 § 3.2(g)(i) 

 

	 	
acquisition or establishment in the case of Real Estate of any Securing Party (or, in each case, such later period as reasonably agreed in writing by the Security Trustee), together with all
documents and instruments required under the law of the jurisdiction in which such deed of trust is to be recorded to perfect the Security Interest of the Security Trustee in such Common Collateral free of any other pledges, security interests or
deeds of trust, except Permitted Liens. 

  

	 	(g)	Excluded Assets 

 Notwithstanding anything to the contrary in this Agreement, this
Agreement shall not constitute a grant of a security interest in any of the following assets, whether now owned or hereafter acquired (collectively, the “Excluded Assets”): 

 

	 	(i)	any assets or property rights of the Securing Parties of any nature to the extent that any applicable law or regulation prohibits the creation of a security interest thereon (other than to the extent that any such law
would be rendered ineffective pursuant to any other applicable law); provided, however, that the Collateral shall include (and the Security Interests shall attach and the definition of Excluded Assets shall not then include)
immediately at such time as the contractual or legal provisions referred to above shall no longer be applicable and to the extent severable, and the Security Interests shall attach immediately to any portion of such assets or property rights not
subject to the provisions in this sub-clause (i); provided further that the exclusions referred to in this sub-clause (i) shall not include any Proceeds of
such assets or property rights; 

  

	 	(ii)	any Permit, lease, license, easement, contract or agreement (other than any Material Project Agreement) to which a Securing Party is a party or any of its rights or interests thereunder or any property or assets of a
Securing Party, in each case if and only to the extent that: 

  

	 	(A)	the grant of a Security Interest hereunder shall constitute or result in a breach of a term or provision of, the termination or forfeiture of (or ability of the other party to void or revoke) or a default, under the
terms of, such Permit, lease, license, easement, contract or agreement; or 

  

	 	(B)	a grant of security interests therein would require governmental consent, approval, license or authorization that has not been obtained; 

provided, however, that 
  

	 	(1)	 the Collateral shall include (and such Security Interest shall attach and the definition of Excluded Assets shall
not then include) immediately at such time as the contractual or legal terms or provisions or governmental consent, approval, license or 

  
 -27- 

 § 3.2(g)(iii) 

 

	 	
authorization referred to above shall no longer be applicable and to the extent severable, and shall attach immediately to any portion of such Permit, lease, license, easement, contract,
agreement, property or asset not subject to the provisions specified in this sub-clause (ii); and 

  

	 	(2)	such exclusion shall not apply (x) to the extent the prohibition is ineffective under applicable anti-assignment provisions of the UCC or other applicable law (including pursuant to
Section 9-406, 9-407, 9-408 or 9-409 of the UCC) or (y) to Proceeds and
receivables of the assets referred to in this sub-clause (ii); 

  

	 	(iii)	any “intent-to-use” application for registration of a Trademark filed pursuant to Section 1(b) of the Lanham Act, 15 U.S.C.
§1051, prior to the filing of a “Statement of Use” pursuant to Section 1(d) of the Lanham Act or an “Amendment to Allege Use” pursuant to Section 1(c) of the Lanham Act with respect thereto, solely to the extent,
if any, that, and solely during the period, if any, in which, the grant of a security interest therein would impair the validity or enforceability of, or any Securing Party’s ownership or rights in or to, any registration that issues from such intent-to-use application under applicable federal law; 

  

	 	(iv)	all (A) segregated Deposit Accounts constituting (and the balance of which consists solely of funds set aside in connection with) cash collateral accounts for deposits permitted under the definition of
“Permitted Liens”, (B) payroll and other employee wage and benefit accounts, if any, (C) tax accounts, (D) escrow accounts (excluding any escrow account established under the EPC Contracts and the funds or other property held in
or maintained in any such account, which shall be subject to Section 3.2(b)(iii)) and (E) margin accounts for Permitted Hedging Instruments in the ordinary course of business (collectively, “Excluded Unsecured Accounts”)
and the funds or other property held in or maintained in any such account; 

  

	 	(v)	without duplication of sub-clause (iv) above, property owned by a Securing Party that is subject to a Permitted Lien pursuant to
sub-clauses (b), (c), (but excluding any escrow account established under the EPC Contracts), (f) (other than to the extent covered by sub-clause (vi) below) or
(k) of the definition thereof; provided, however that no property owned by a Securing Party shall be an Excluded Asset solely by reason of being subject to a Permitted Lien unless such Permitted Lien prohibits the granting pursuant to
this Agreement of the respective security interest in such property; 

  
 -28- 

 § 3.2(g)(vii) 

 

	 	(vi)	property owned by a Securing Party that is subject to a purchase money Lien or capital lease permitted under each of the Senior Debt Instruments (including, to the extent applicable, Section 12.14(g) (Limitation
on Indebtedness) of the Common Terms Agreement and any comparable provision in any other Senior Debt Instrument then in effect) if the agreement pursuant to which such Lien is granted (or the document providing for such capital lease) prohibits,
or requires the consent of any Person other than such Securing Party which has not been obtained as a condition to, the creation of any other Lien on such property; 

 

	 	(vii)	the Securing Party’s right, title and interest, as tenant, subtenant or assignee under any real property sub-lease or lease, including in respect of any Fixtures related to
such real property, for offices so long as such offices are not located on the Site; 

  

	 	(viii)	insurances covering workers’ compensation and employers’ liability and any proceeds thereof; and 

  

	 	(ix)	those assets as to which the Security Trustee and the Company reasonably agree from time to time in writing that either (1) the cost of obtaining a security interest in or perfection thereof, (2) the adverse
tax consequences to the Securing Parties, or (3) the adverse regulatory consequences to the Securing Parties, the Project Facilities (or, if not yet included therein, the Second Phase Facilities) or the Development (or, if not yet included
therein, the Second Phase Development), in each case, is or are excessive in relation to the benefit to the Secured Parties of the security afforded thereby. 

  

	 	3.3	Security Interests to be Granted by Holdco 

 By the Second Phase Closing Date, the
Company shall cause Holdco to execute, for the benefit of the Secured Parties, as security for the Senior Debt Obligations and for the Securing Parties’ other obligations under this Agreement and the other Finance Documents, an amended and
restated pledge agreement (the “Holdco Pledge Agreement”) in the form attached hereto as Schedule F (Form of Holdco Pledge and Security Agreement). The Holdco Pledge Agreement shall provide for a first priority perfected
security interest, subject only to the Permitted Lien described in clause (a) of the definition thereof, in the right, title and interest of Holdco in all the limited liability company interests of the Company and the Proceeds thereof, all as
more fully described in the Holdco Pledge Agreement. For the avoidance of doubt, such Security Interests granted by Holdco shall be included in the Common Collateral. 
  

	 	3.4	Direct Agreements 

  

	 	(a)	Prior to Second Phase Closing, the applicable Securing Party that is the party to the relevant agreement referred to below shall enter into Direct Agreements with the Security Trustee solely with the following entities
and such Direct Agreements shall be substantially in the forms noted below: 

  

	 	(i)	the LNG Buyers under each of the Second Phase LNG SPAs and any guarantors of such LNG Buyers (substantially in the agreed form attached to the applicable LNG SPA or otherwise in substantially the applicable form
attached hereto in Schedule G (Forms of Direct Agreements); 

  
 -29- 

 § 3.4(b) 

 

	 	(ii)	PetroChina and the PetroChina Guarantor under the PetroChina DES LNG SPA (substantially in the agreed form attached to the PetroChina DES LNG SPA); 

 

	 	(iii)	the EPC Contractor and any guarantor thereof under the EPC Contract (T3) (substantially in the agreed form attached to such EPC Contract); and 

 

	 	(iv)	the Technology Licensor under the Technology License Agreement (T3) (substantially in the form attached hereto as Schedule G-4 (Forms of Direct Agreement – Form of
Direct Agreement for Technology Licensor under the ConocoPhillips License Agreements)). 

  

	 	(b)	[Reserved] 

  

	 	(c)	With respect to any non-Qualifying LNG SPA executed with an Affiliate of the Loan Parties after the Second Phase Closing Date, on or prior to the date of execution of such LNG
SPA, the Securing Party that is party to the relevant agreement shall enter into a Direct Agreement with the Security Trustee and the LNG Buyer and any guarantors of such LNG Buyer (with respect to such LNG Buyer, substantially in the form attached
hereto as Schedule G-5-2 (Forms of Direct Agreement – Form of Direct Agreement for Affiliate Non-Qualifying LNG SPAs)
and with respect to any guarantor of such LNG Buyer, substantially in the form attached hereto as Schedule G-3 (Forms of Direct Agreement – Form of Direct Agreement for Guarantees)).

  

	 	(d)	With respect to any Qualifying LNG SPA executed after the Second Phase Closing Date, on or prior to the date of execution of such LNG SPA, the Securing Party that is party to the relevant agreement shall enter into a
Direct Agreement with the Security Trustee and the LNG Buyer and any guarantors of such LNG Buyer (with respect to such LNG Buyer, substantially in the form attached hereto as Schedule G-2 (Forms of Direct
Agreement – Form of Direct Agreement for Material Project Agreements with non-Affiliates) and with respect to any guarantor of such LNG Buyer, substantially in the form attached hereto as Schedule G-3 (Forms of Direct Agreement – Form of Direct Agreement for Guarantees)). 

  

	 	(e)	The Securing Party that is party to the relevant agreement shall use commercially reasonable efforts to obtain, on or prior to the date of execution: (i) Direct Agreements with respect to any precedent pipeline
agreements that are Subsequent Material Project Agreements entered into by CCL with Qualified Transporters, substantially in the form attached hereto as Schedule G-2 (Forms of Direct Agreement –
Form of Direct Agreement for Material Project Agreements with non-Affiliates), and (ii) the contractor and any guarantor thereof under any engineering, procurement and construction contract in
respect of the Corpus Christi Pipeline if it is a Subsequent Material Project Agreement, substantially in the applicable form attached hereto as Schedule G-6 (Forms of Direct Agreement –
Forms of Direct Agreement for Contractor, and any Guarantor of such Contractor’s Obligations, under an Engineering, Procurement and Construction Contract), or, in each case of clauses (i) and (ii), in a form reasonably
acceptable to the Security Trustee. 

  
 -30- 

 § 3.4(f) 

 

	 	(f)	For the avoidance of doubt, the Securing Parties shall not be required to obtain Direct Agreements, including from any Qualified Transporters under any Gas transportation agreements (other than precedent agreements),
Gas suppliers under any Gas supply agreements, LNG Buyers or guarantors of LNG SPAs, in each case other than those set forth above. 

  

	 	(g)	The Security Trustee shall give irrevocable instructions to each LNG Buyer to make all payments of LNG sales revenues and other payments due to CCL under any LNG SPA to the Equity Proceeds Account (for payments prior to
the Project Completion Date) and to the Revenue Account (for payments after the Project Completion Date), which shall be identified in writing by the Security Trustee to each LNG Buyer in its Direct Agreement, and each LNG Buyer shall confirm its
agreement to do so in the terms of its Direct Agreement. 

  

	 	(h)	The Company shall deliver to the Security Trustee executed counterparts of any Direct Agreements and consents entered into after the date of this Agreement in accordance with this Section 3.4 (Direct
Agreements) by the date stated herein or, where not stated, as soon as reasonably practicable. 

  

	 	(i)	The Security Trustee is hereby authorized and directed by the Secured Parties to execute each of the Direct Agreements contemplated above without further action by the Senior Creditors. 

 

	 	(j)	The Security Trustee is hereby authorized to countersign, to the extent such countersignature is required, any direction to PetroChina to pay the PetroChina Payments (as defined in the CMI Security Agreement) related to
a Swapped Cargo (as defined in the CMI Security Agreement) into an account other than the Deposit Account (as defined in the CMI Security Agreement) upon notification to the Security Trustee by the Company that the applicable diversion conditions in
the CMI Security Agreement have been satisfied. 

  

	 	3.5	Perfection and Maintenance of Security Interests 

  

	 	(a)	

  

	 	(i)	Subject to any exceptions set forth in this Section 3.5, from and after the Closing Date, the Securing Parties have caused and shall cause Holdco to, maintain the Security Interests created by the Security
Documents as a perfected security interest having at least the priority described in Sections 3.2 (Security Interests to be Granted by the Securing Parties) and 3.3 (Security Interests to be Granted by Holdco). 

  
 -31- 

 § 3.5(a)(ii) 

 

	 	(ii)	Subject to any exceptions set forth in this Section 3.5, at any time and from time to time, upon the reasonable written request of the Security Trustee, the Securing Parties shall, and shall cause Holdco to, at the
Securing Parties’ expense, promptly take all such further actions as reasonably may be requested by the Security Trustee (including, where applicable, the giving, execution, filing, authentication and/or recording of any notice, Financing
Statement, Continuation Statement, public deed, deed of trust, instrument, document or agreement) (A) in order to preserve, continue and perfect (including, where required, by control) the Security Interests (including, to the extent available
under applicable law, the priority of any such Security Interest) and enable the Security Trustee for the benefit of the Secured Parties to exercise or enforce its rights hereunder, under any other Security Documents or under the Direct Agreements
with respect to such Security Interest in the manner contemplated hereby and by the Senior Debt Instruments and any Permitted Senior Debt Hedging Instruments and at, where applicable, the times indicated in the applicable Security Documents and
Direct Agreements and (B) for the purpose of obtaining or preserving the full benefits of this Agreement and the other Security Documents and Direct Agreements and of the rights and powers granted herein and therein. 

 

	 	(b)	Collateral in Possession of Bailee; Perfection. If any goods (excluding Gas) in which any Securing Party owns or has an interest are now or at any time in the possession of a bailee and the value of such goods in
the possession of such bailee is above $10,000,000: 

  

	 	(i)	such Securing Party shall use reasonable efforts to obtain an acknowledgment from each such bailee, in form and substance reasonably satisfactory to the Security Trustee as it may request, that each such bailee holds
such Collateral for the benefit of the Security Trustee and, if notice of the occurrence and continuation of an Event of Default has been provided, such bailee shall act upon instructions from the Security Trustee, without the further consent of
such Securing Party; and 

  

	 	(ii)	if for any reason the Security Trustee does not have a perfected security interest in such goods in possession of a bailee, then such Securing Party shall promptly transport such goods to the Project Facilities or to
another location with respect to which the Security Trustee will have a perfected security interest. 

  

	 	(c)	 Electronic Chattel Paper and Transferable Records. With respect to all electronic chattel paper or any
“transferable record”, as that term is defined in Section 201 of the federal Electronic Signatures in Global and National Commerce Act or in Section 16 of the Uniform Electronic Transactions Act as in effect in any relevant
jurisdiction, now or hereafter acquired by or arising in favor of any Securing Party, such Securing Party shall promptly take such action as necessary to vest in the Security Trustee “control” (as defined in
Section 9-105 of the UCC) of such electronic chattel paper or “control” under Section 201 of the federal Electronic Signatures in Global and National Commerce Act or, as the case may be,

  
 -32- 

 § 3.5(d) 

 

	 	
Section 16 of the Uniform Electronic Transactions Act, as so in effect in such jurisdiction, of such transferable record. A Securing Party may arrange, pursuant to procedures that will not
result in the Security Trustee’s loss of control, for such Securing Party to make alterations to the electronic chattel paper or transferable record permitted under the UCC or, as the case may be, Section 201 of the Electronic Signatures
in Global and National Commerce Act or Section 16 of the Uniform Electronic Transactions Act for a party in control to make without loss of control, unless an Event of Default has occurred and is continuing or would occur after taking into
account any action by such Securing Party with respect to such electronic chattel paper or transferable record. Notwithstanding the foregoing, the requirements set forth in this clause (c) are subject to the limitations on perfection and method
of perfection set forth in clause (d) below. 

  

	 	(d)	The perfection of the security interest granted in Section 3.2(b)(vi) (Security Interests to be Granted by the Securing Parties – Security Interests – General) in Chattel Paper (whether
tangible or electronic) will, prior to the occurrence of an Event of Default (and after the occurrence of an Event of Default unless the Security Trustee has required that further actions in accordance with the other provisions hereof are taken with
respect to the perfection thereof), be effected solely by filing an appropriate financing statement under the UCC. 

  

	 	(e)	From and after the Closing Date, with respect to any Letter-of-Credit Rights, the Securing Parties have ensured and shall ensure that, as
promptly as reasonably practicable after receipt of a Letter-of-Credit, the Security Trustee has control thereof by ensuring that the Security Trustee takes possession
thereof and obtaining a written consent from each issuer of each related letter of credit to the assignment of the proceeds of such letter of credit to the Security Trustee, except for
(i) Letter-of-Credit Rights under any letters of credit which, at the time they are granted to a Securing Party, have a face value of less than $10,000,000
individually or $40,000,000 in the aggregate or (ii) from and after the Second Phase Closing Date, Letter-of-Credit Rights granted by CMI (UK) to CCL under the CMI
Security Agreement. 

  

	 	(f)	The perfection of the security interest in motor vehicles and other assets subject to Certificates of Title shall only be required after the aggregate value of all motor vehicles and such other assets owned by the
Securing Parties at any given time exceeds $2,500,000 and shall only be required for the motor vehicles and assets above that threshold. 

  

	 	(g)	Intellectual Property Recording Requirements 

  

	 	(i)	 Schedule J (Intellectual Property) lists all of the following Intellectual Property, to the extent owned
by a Securing Party, held as of the Second Phase Closing Date and material to the business of a Securing Party: (A) issued Patents, pending Patent applications and Patent Licenses, (B) registered Trademarks, applications for the
registration of Trademarks and Trademark Licenses, 

  
 -33- 

 § 3.5(g)(i) 

 

	 	
and (C) registered Copyrights, applications for the registration of Copyrights and Copyright Licenses (in each case, other than Intellectual Property licenses entered into in the ordinary
course of business, including any Copyright Licenses with respect to off-the-shelf software). From and after the Second Phase Closing Date, if the Securing Parties shall
at any time hold or acquire any Intellectual Property of the type described in sub-clause (A), (B) or (C) above and that is owned by a Securing Party and material to the business of a Securing Party, the
Securing Parties shall promptly provide the Security Trustee with a supplement to Schedule J (Intellectual Property), describing such Intellectual Property. For the avoidance of doubt, the Technology License Agreement (T1/T2) and the
Technology License Agreement (T3) or any Intellectual Property arising thereunder shall not be required to be listed on Schedule J (Intellectual Property). 

 

	 	(ii)	From and after the Second Phase Closing: 

  

	 	(A)	subject to Section 3.2(g)(iii) (Security Interests to be Granted by the Securing Parties – Excluded Assets), in the case of any Collateral (whether now owned or hereafter acquired)
consisting of registered US Trademarks and applications therefor, the Securing Parties shall execute and deliver to the Security Trustee a Trademark security agreement in form and substance reasonably acceptable to the Security Trustee covering all
such US registered Trademarks and applications therefor in appropriate form for recordation with the USPTO with respect to the Security Interest of the Security Trustee; and 

 

	 	(B)	in the case of any Collateral (whether now owned or hereafter acquired) consisting of (1) US Patents and applications therefor or (2) US registered Copyrights and exclusive US Copyright Licenses, the Securing
Parties shall execute and deliver to the Security Trustee a Patent security agreement or Copyright security agreement, as applicable in form and substance reasonably acceptable to the Security Trustee covering all such US Patents or US Copyrights
and applications for US Patents and US Copyright and exclusive US Copyright Licenses in appropriate form for recordation with the USPTO or United States Copyright Office, as applicable, with respect to the Security Interest of the Security Trustee.

  

	 	(iii)	 For the purpose of enabling the Security Trustee to exercise rights and remedies under Article 6 (Security
Trustee Action), following such time as a Declared Event of Default has occurred and is continuing, and for no other purpose, the Securing Parties shall give the Security Trustee reasonable access to all media in which any of the Intellectual
Property Collateral may be recorded or stored and to all computer programs used 

  
 -34- 

 § 3.5(g)(iv) 

 

	 	
for the compilation or printout thereof. In the event of a disposition of any of the Intellectual Property Collateral by the Security Trustee hereunder in accordance with the terms of this
Agreement, each Securing Party shall use commercially reasonable efforts to supply the Security Trustee or the assignee of such Intellectual Property with such know-how and expertise, and with documents and
materials embodying the same, relating to the use of the disposed Intellectual Property in connection with the Project Facilities. 

  

	 	(iv)	Subject to the provisions of this Agreement and the other Finance Documents that limit the rights of any Securing Party to dispose of its property and rights and remedies of the Security Trustee as set forth herein, the
Securing Parties shall otherwise retain all right, title and interest in, to and under the Intellectual Property now owned or hereafter acquired by such Securing Party, including the full right to exploit, use, enjoy, protect, enforce or take other
actions with respect to such Intellectual Property. To the extent required under applicable law for any Securing Party to exercise its rights with respect to such Intellectual Property, the Security Trustee shall, upon the reasonable request of any
Securing Party, reasonably cooperate with such Securing Party and execute and deliver documents so requested by such Securing Party. The exercise of rights and remedies under Article 6 (Security Trustee Action) by the Security Trustee shall
not terminate or limit the rights of the holders of any licenses or sublicenses theretofore granted by such Securing Party in accordance with the first sentence of this sub-clause (iv). 

 

	 	(v)	Notwithstanding anything to the contrary in the Finance Documents (including clause (a) above), any reference to perfection of Security Interests with respect to Intellectual Property in any of the Finance
Documents shall be deemed to mean perfection of such Security Interests to the extent perfection can be obtained by the filing of Patent security agreements and Trademark security agreements at the USPTO and the filing of Copyright security
agreements at the United States Copyright Office or by the filing of a UCC-1 financing statement in the relevant jurisdiction. 

 

	 	(h)	If the Securing Parties shall at any time hold or acquire a Commercial Tort Claim with a value in excess of $5,000,000, the Securing Parties shall promptly provide the Security Trustee with a supplement to Schedule E
(Commercial Tort Claims) hereto, which supplement shall include a summary description of such claim and grant to the Security Trustee, for the ratable benefit of the Secured Parties, a Security Interest therein and in the proceeds thereof,
all upon the terms of this Agreement. 

  

	 	(i)	With respect to any Collateral hereafter owned or acquired, the Securing Parties shall comply with the applicable perfection requirements in clauses (a) through (h) above within 30 days of the Securing Parties
acquiring rights therein, or if such rights are acquired after the date of this Agreement but prior to Second Phase Closing, by Second Phase Closing. 

  
 -35- 

 § 3.5(j)(i) 

 

	 	(j)	Subject to the limitations, and except as otherwise expressly provided for, in this Agreement and the other Security Documents, and to the extent permitted by applicable law, the Security Trustee is authorized to:

  

	 	(i)	file under the UCC of any state of the United States or other applicable law, Financing Statements, Continuation Statements or other documents relating to the Collateral; 

 

	 	(ii)	file with the USPTO or United States Copyright Office (or any successor office), as applicable, such documents as may be necessary or advisable for the purpose of perfecting, confirming, continuing, enforcing or
protecting the Security Interests granted by the Company hereunder; 

  

	 	(iii)	take any action to ensure that the Security Interests in the Collateral are enforceable, perfected (including, where possible, by control in addition to registration) and otherwise effective; 

 

	 	(iv)	apply for registration, or give any notification, in connection with the Security Interests so that such Security Interests have the priority required by the Secured Parties; and 

 

	 	(v)	otherwise exercise the rights of the Secured Parties in connection with the Security Interests, 

in each case without the signature of a Securing Party or Holdco (unless such signature is required by applicable law) and naming a Securing
Party or Holdco as debtor and the Security Trustee as secured party. 
  

	 	(k)	Except as otherwise provided in this Agreement or any other Security Document, the Security Trustee shall not be responsible for the creation, perfection, validity, sufficiency or enforceability of any Security Interest
created or intended to be created hereby or pursuant hereto or for the maintenance or perfection of any such Security Interests; provided that the Security Trustee shall promptly execute all public deeds or other documents as required by
applicable law and regulation in the various jurisdictions as reasonably requested by any Senior Creditor Group Representative, to duly create and register the Security Interests as provided for in this Article 3 (Security Interests). In the
event that the Security Trustee takes any action under this Section 3.5 (Perfection and Maintenance of Security Interests), the Security Trustee shall promptly notify the applicable Securing Party thereof following the taking of such
action. 

  
 -36- 

 § 3.5(l)(ii) 

 

	 	(l)	With respect to Pledged Collateral: 

  

	 	(i)	each applicable Securing Party agrees to promptly deliver or cause to be delivered to the Security Trustee any and all Pledged Collateral in which the applicable Securing Party now has or hereafter acquires an interest
(to the extent represented or evidenced by a certificate, instrument or other transferable document); 

  

	 	(ii)	upon delivery to the Security Trustee, any certificate, instrument or document representing or evidencing Pledged Collateral shall be accompanied by undated membership interest, stock or note powers, as applicable, duly
executed in blank or other undated instruments of transfer reasonably satisfactory to the Security Trustee and duly executed in blank and by other instruments and documents as the Security Trustee may reasonably request; and 

 

	 	(iii)	the Security Trustee, on behalf of the Secured Parties, shall have the right (in its sole and absolute discretion) to hold the Pledged Collateral in its own name as pledgee, or in the name of its nominee (as pledgee or
as sub-agent). 

  

	 	(m)	The Security Interest granted to the Security Trustee hereunder consisting of personal property will be perfected (i) with respect to any Collateral that can be perfected by filing UCC financing statements, upon
the filing of UCC financing statements in the filing offices identified in Schedule L (UCC Filing Offices), (ii) with respect to any Collateral constituting Securities Accounts or Deposit Accounts (excluding any escrow account established
under the EPC Contracts) that can be perfected solely by control, upon execution of this Agreement, and (iii) with respect to any Collateral that can be perfected solely by possession, upon the Security Trustee receiving possession thereof in
accordance with the requirements of this Agreement or another Security Document. In each case such security interest will be, as to Collateral perfected as aforesaid, superior and prior to the rights of all third Persons now existing or hereafter
arising as a result of any Lien, in each case subject only to Permitted Liens. All of such above-referenced action as is necessary will be taken on or prior to the Second Phase Closing Date to the extent so required herein and in the applicable
Senior Debt Instrument to establish and perfect the Security Trustee’s rights in and to the Collateral and first priority Lien, subject to Permitted Liens, on the Collateral, including any recordation, filing, registration, giving of notice or
other similar action. No filing, recordation, re-filing or re-recording other than those listed on Schedule L (UCC Filing Offices) or otherwise required
under the Security Documents is necessary to perfect (or maintain the perfection of, other than the filing of UCC-3 continuation statements) the Liens of the Security Documents (to the extent the Security
Trustee’s Security Interest can be perfected by filing). For the avoidance of doubt, in no event shall any control agreements be required in respect of any escrow accounts established under the EPC Contracts. 

 

	 	(n)	 The Securing Parties shall not take any action, and shall procure that Holdco take no action, that would or could
reasonably be expected to have a material adverse effect on the perfection or first-ranking priority of the Security Interests, subject 

  
 -37- 

 § 3.5(n) 

 

	 	
in each case to Permitted Liens to the extent specified herein; provided that the Securing Parties shall not be required to take any action to perfect security interests in Excluded Assets
or otherwise listed as an exception to the perfection requirements of this Section 3.5 (Perfection and Maintenance of Security Interests). 

  

	 	(o)	Fair Labor Standards Act. Each Securing Party represents and warrants to and in favor of the Security Trustee and each of the other Secured Parties that any goods now or hereafter produced by the Securing Party
or any of its Subsidiaries included in the Collateral have been and will be produced in compliance with the requirements in the Fair Labor Standards Act. 

  

	 	3.6	Rights in Collateral Prior to Security Enforcement Action 

  

	 	(a)	Subject to the provisions of Section 4.6(a) (Control and Investment of Funds in Accounts), notwithstanding the Security Interests created, and to be created, pursuant to the Security Documents, unless
otherwise provided in this Agreement or another Finance Document, or unless the Security Trustee shall have delivered a Notice of Security Enforcement Action, in each case with respect to the relevant Collateral, the Securing Parties and Holdco
shall retain and be entitled to exercise all of their respective rights relating to the Collateral including, and to the extent applicable to the relevant Person (but subject, in each case, to the terms and conditions of this Agreement and each
other Finance Document), the following: 

  

	 	(i)	possessing and using the Project Facilities and other Project Property, receiving the revenues and profits to be derived therefrom, and altering or disposing of any part thereof; 

 

	 	(ii)	exercising all rights arising from and relating to LNG SPAs, including amending LNG SPAs and instituting and settling proceedings to enforce their rights thereunder; 

 

	 	(iii)	renewing, amending and cancelling insurance policies, making claims and instituting and settling proceedings against insurers thereunder; 

 

	 	(iv)	transferring (in accordance with the Finance Documents) the interests of Holdco, receiving the profits to be derived from any interest in a Securing Party and exercising rights (including voting rights) as a member of
the Company or CCL or CCP GP or a general or limited partner of CCP; 

  

	 	(v)	receiving payments of principal and interest on Subordinated Debt where payable thereunder in compliance with the terms of the applicable subordination agreement; 

 

	 	(vi)	subject to the obligation to deposit the relevant amounts in the Insurance/Condemnation Proceeds Account under Section 5.2 (Insurance and Condemnation Proceeds), receiving payment of Insurance Proceeds and
Condemnation Proceeds in respect of the Project Facilities and making claims and instituting and settling proceedings for the recovery thereof; and 

  
 -38- 

 § 3.6(a)(vi) 

 

	 	(vii)	exercising all rights arising from and relating to the Material Project Agreements and amending each of the Material Project Agreements, making waivers and elections thereunder and instituting and settling proceedings
for the enforcement of rights thereunder. 

  

	 	(b)	Subject to the provisions of Section 4.6(a) (Control and Investment of Funds in Accounts), unless the Security Trustee shall have delivered a Notice of Security Enforcement Action, the Security Trustee and
each Secured Party shall, at the request and sole cost of the Securing Parties, provide written confirmations or otherwise take such actions and do such things as may be reasonably necessary to enable the Securing Parties to exercise rights retained
by them in the relevant Collateral that may be constrained, or perceived as constrained, by the existence of the Security Interests; provided, in each case, that no such confirmation, action or filing shall in the determination of the Secured
Parties have any adverse effect on the legality, validity, priority and perfection of the Security Interests and shall not otherwise adversely affect the rights and remedies of the Secured Parties under the Finance Documents. The Secured Parties
shall act in respect of the Collateral in accordance with this Agreement, including with respect to undertaking enforcement procedures in respect hereof. 

  

	 	3.7	Liability of Securing Parties Under Contracts or Agreements Included in the Collateral 

  

	 	Notwithstanding	any other provision of this Agreement or any other Finance Document, and subject to applicable law: 

  

	 	(a)	each Securing Party shall remain liable under all agreements and contracts to which it is a party that are included in the Collateral and nothing contained herein or in any other Finance Document is intended to or shall
be a delegation of duties to the Security Trustee or any Secured Party; 

  

	 	(b)	the exercise by any of the Secured Parties of any of their respective rights under this Agreement or any other Finance Document shall not release any Securing Party from any of its duties or obligations under any
contracts or agreements that are included in the Collateral, except to the extent provided in the applicable Direct Agreement; and 

  

	 	(c)	none of the Secured Parties shall have any obligation or liability under any contracts or agreements that are included in the Collateral solely by reason of this Agreement or any other Finance Document, nor shall any of
them thereby be obligated to: 

  

	 	(i)	perform any of the Securing Parties’ or Holdco’s obligations or duties thereunder; 

  
 -39- 

 § 3.7(c)(iii) 

 

	 	(ii)	make any inquiry as to the nature or sufficiency of any payment received by it; or 

  

	 	(iii)	take any action or collect or enforce any rights or claim for payment under any such contract or agreement. 

  

	 	3.8	Release or Modification of Security Interests 

  

	 	(a)	The Security Interests granted to the Security Trustee by the Collateral Parties in any Collateral shall be released, and to the extent permitted under applicable law, shall be automatically released, in the following
events: 

  

	 	(i)	in full upon termination of this Agreement pursuant to Section 12.1 (Termination); 

  

	 	(ii)	in respect of any Project Property constituting Collateral that is sold, leased or otherwise disposed of as permitted under the terms of each Senior Debt Instrument then in effect (including, to the extent applicable,
Section 12.17 (Sale of Project Property) of the Common Terms Agreement) and the other Finance Documents; provided that the proceeds of such sale, lease or disposition, as applicable, are applied in accordance with the Finance
Documents; 

  

	 	(iii)	upon any Project Property becoming Excluded Assets; 

  

	 	(iv)	in respect of any Disbursement Account, at any time the Disbursement Account is closed as permitted in this Agreement; provided that no cash, Financial Assets or other property or investments (including
Authorized Investments) remain on deposit or credited to such Disbursement Account at such time; 

  

	 	(v)	in respect of all cash, Financial Assets or other property credited to or held in any Senior Note Disbursement Account, investments (including any Authorized Investments) made with or arising out of such funds and all
proceeds of the foregoing, if any conditions to the disbursement of such cash, Financial Assets or other property to the Company have not been either satisfied or waived and such cash, Financial Assets or other property are required, by the terms of
the relevant Senior Debt Instrument, to be returned to the relevant Senior Noteholders, upon such return; 

  

	 	(vi)	in respect of any proceeds of third party liability insurance permitted to be paid to third parties or proceeds of builder’s risk insurance or marine cargo permitted to be paid directly to the EPC Contractor
pursuant to Section 5.2 (Insurance and Condemnation Proceeds); and 

  

	 	(vii)	where directed by Requisite Secured Parties pursuant to Section 7.2(a) (Modification Approval Levels – Modifications to this Agreement). 

  
 -40- 

 § 3.8(b)(i) 

 

	 	(b)	In connection with any release pursuant to this Section 3.8 (Release or Modification of Security Interests): 

  

	 	(i)	The Security Trustee shall promptly (and the Secured Parties hereby authorize and direct the Security Trustee to) take such action and execute any such documents as may be reasonably requested by a Securing Party, at
such Securing Party’s expense, in connection with the release of any Security Interests created by any Finance Document in respect of such property or asset. 

 

	 	(ii)	To the extent a Security Trustee action or Decision is required or requested in connection with such release of Collateral, the Company shall deliver to the Security Trustee on or prior to the date of the proposed
release a written request for release identifying the relevant Collateral to be released, together with a certification by the Company stating (and providing reasonable detail and other available supporting information) that such transaction is in
compliance with the Finance Documents and that the Proceeds of such disposition shall be applied in accordance therewith. 

  

	 	(iii)	The Secured Parties hereby authorize and instruct the Security Trustee (at the sole cost and expense of the Securing Parties) to amend the Security Documents and the Direct Agreements and execute and deliver any
instruments, documents and agreements, and otherwise do all things necessary to accomplish, evidence and confirm the release of any Collateral pursuant to the foregoing provisions of this Section 3.8 (Release or Modification of Security
Interests), all without the further consent or joinder of any Secured Party. In the event of any release of Collateral relating to the Accounts, the Security Trustee shall notify the Account Bank in writing. 

 

	4.	CASH FLOW AND ACCOUNTS 

  

	 	4.1	General Principles 

  

	 	(a)	The Company has established and shall maintain, in the name of the Company, the Accounts in accordance with Section 4.3 (Accounts). 

 

	 	(b)	 Each Guarantor hereby irrevocably grants authority to the Company to establish and maintain such Accounts on its
behalf. The initial Accounts details are set forth in Schedule H (Details of Initial Accounts). For the avoidance of doubt, (i) the Excluded Unsecured Accounts, if established, shall not constitute “Accounts” for purposes of
this Agreement or any other Finance Document and none of the Securing Parties, Holdco, the Sponsor or any of their respective Affiliates shall be obliged to grant, create or maintain any Security Interest in relation to such accounts; (ii) the
Individual Senior Noteholder Secured Account need only be established by the Company at the time amounts 

  
 -41- 

 § 4.1(b) 

 

	 	
are required to be paid into such account in accordance with Section 4.5(j) (Deposits and Withdrawals – Mandatory Prepayment Senior Notes Account) or Section 3.2(c)(i)
(Security Interests to be Granted by the Securing Parties – Security Interests – Individual Senior Noteholder Secured Accounts), as applicable; (iii) the Disbursement Accounts may be closed following the expiry of the
availability period of any Senior Debt Commitments that are to be disbursed therein; provided that any cash, Financial Assets or other property or investments (including Authorized Investments) credited to or on deposit in any Disbursement
Account have been transferred to the Construction Account (prior to the Project Completion Date) or to the Senior Debt Service Reserve Account or the Revenue Account (after the Project Completion Date) and (iv) any escrow accounts established
under the EPC Contracts shall not constitute “Accounts” for purposes of this Agreement or any other Finance Document but shall be subject to the Lien established pursuant to Section 3.2(b)(iii) (Security Interests to be Granted by
the Securing Parties – Security Interests – General), subject to Section 3.5(n) (Perfection and Maintenance of Security Interests). 

  

	 	(c)	Neither the existence of the Accounts, nor the insufficiency of funds in any of them, nor any inability to apply any funds in them towards the relevant payment shall affect the obligation of the Securing Parties to make
all payments required to be made to the Secured Parties or any of them on the due date for such payments in accordance with this Agreement or any other Finance Document. 

 

	 	(d)	No sum may be credited to, or withdrawn from, any Account except as expressly permitted or required by this Agreement. 

  

	 	(e)	The Company may from time to time grant the Manager a power of attorney or signature authority over the Accounts to administer such accounts on behalf of, and in the name of, the Company. The Company shall notify the
Security Trustee and the Account Bank in writing of any such grant of authority to administer the Accounts promptly following such authorization. Without prejudice to any and all obligations and liabilities of the Company under this Agreement and
any other Finance Document, it is acknowledged by each party hereto that, upon such written notification to the Security Trustee and the Account Bank, any reference in the Finance Documents to actions by the Company in respect of the Accounts shall
be deemed to include, and permit, actions in respect of such Accounts by the Manager if authorized by the Company to administer the Accounts. If the Manager is authorized by the Company to administer the Accounts, the Company shall be liable for any
such actions taken by the Manager as if the Company took each such action. Together with any such notice to the Account Bank, the Company shall provide an updated duly executed incumbency certificate or other written instructions showing the names,
titles and specimen signatures of the Persons authorized on behalf of the Manager to take actions and provide certifications as required hereunder, including the execution and delivery of any Withdrawal and Transfer Certificate. 

  
 -42- 

 § 4.1(f) 

 

	 	(f)	From and after the Closing Date, all of the Company’s funds have been and shall be held in (i) the Accounts; or (ii) to the extent such funds are to be used solely for the purposes described in the
definition thereof, any Excluded Accounts. 

  

	 	(g)	From and after the Closing Date, the Company has not and shall not open or maintain accounts in its name, or cause accounts to be opened or maintained in its name, other than the Accounts and the Excluded Accounts. For
the avoidance of doubt, the Excluded Accounts are not required to be maintained with the Account Bank. 

  

	 	(h)	Notwithstanding anything in this Agreement to the contrary, any payments and receipts of funds made between or among the Securing Parties shall be documented as payments and receipts within the books and records of the
Securing Parties but shall not require a transfer of funds within the Accounts. 

  

	 	(i)	The Account Bank shall maintain records of all deposits into and transfers to and from the Accounts and all investment transactions effected by the Account Bank pursuant to the terms hereof, and any such recordation
shall constitute prima facie evidence of the information recorded. The Account Bank shall promptly respond (during normal business hours) to requests by the Security Trustee and the Company for information regarding deposits, withdrawals,
investments and transfers into, in respect of and among Accounts and balances in the Accounts. The Account Bank shall provide the Security Trustee and the Company with online access to review all account activities of the Accounts.

  

	 	4.2	Authorized Investments 

  

	 	(a)	Authorized Investments. All funds in the Accounts shall only be invested in Authorized Investments and all funds in Excluded Accounts shall only be invested in Authorized Investments, unless otherwise
required by applicable law, in which case such funds shall be invested in accordance with such applicable law. All references in this Agreement to Accounts and to cash, monies or funds therein or balances thereof shall include the Authorized
Investments in which such monies are then invested and (without duplication) the proceeds of those investments. 

  

	 	(b)	Directing the Making of Investments. Pending the application of funds in accordance with Section 4.7 (Cash Waterfall) or as otherwise permitted, required or contemplated by this Agreement, any cash
held in Accounts maintained hereunder shall be invested in Authorized Investments from time to time by the Account Bank at the expense and risk of the Company as directed in writing by the Company or the Security Trustee, in accordance with
Section 4.6 (Control and Investment of Funds in Accounts); provided, however, that the Account Bank’s obligation to invest such amounts is conditioned upon receipt by the Account Bank of a valid Form W-9 of the Internal Revenue Service of the United States of America in accordance with clause (c) below. The right of the Company or the Security Trustee, as applicable, to direct the manner of investment
includes the 

  
 -43- 

 § 0 
  

	 	
right (i) to direct the Account Bank to sell any Authorized Investment or hold it until maturity, (ii) upon any sale of any Authorized Investment, to direct the Account Bank to reinvest
the proceeds thereof, plus any interest received by the Account Bank thereon, in Authorized Investments or to hold such proceeds and interest for application pursuant to the terms of this Agreement, and (iii) to exercise any voting rights with
respect to any Authorized Investment. No Secured Party shall have any liability for any loss resulting from any such investment other than any such loss caused solely by such Secured Party’s willful misconduct, fraud or gross negligence as
determined by a court of competent jurisdiction in a final and non-appealable judgment. The Account Bank shall have no obligation to invest funds in Authorized Investments in the absence of an instruction from
the Company or the Security Trustee. Instructions received after 12:00 pm New York City time will be deemed received the next Business Day. 

  

	 	(c)	Earnings. All earnings on funds in any Account maintained hereunder shall be credited to the Company for tax reporting purposes. The Company shall provide the Account Bank with its taxpayer identification
number, documented, to the extent necessary, by an appropriate executed Form W-9, upon execution of this Agreement. The Form W-9 shall, to the extent necessary, be
renewed by the Company as required by the Internal Revenue Service of the United States of America and provided to the Account Bank. 

  

	 	(d)	Value of Authorized Investments. Authorized Investments credited to any Account shall be valued at their then-current market value. 

 

	 	(e)	Security Interest in Authorized Investments. Whenever the Company directs the Account Bank to purchase an Authorized Investment not represented or evidenced by certificates or instruments capable of
possession, the Company shall notify the Security Trustee in writing of such directed purchase and, upon the request of the Security Trustee, the Account Bank will deliver such information to the Security Trustee as may be reasonably necessary to
enable the Security Trustee to take all necessary action, including giving confirmations and notices to record the Security Trustee’s interest therein, as required by the UCC to perfect a first priority security interest therein (subject to
Permitted Liens) for the benefit of the Security Trustee (on behalf of the Secured Parties). Without limiting the foregoing, whenever the Account Bank purchases an Authorized Investment which is a certificate of deposit, the Account Bank shall
simultaneously or promptly thereafter notify the issuer of the certificate of deposit in writing as follows: Société Générale, as the Security Trustee for the Secured Parties, has a security interest in and pledge of the
certificate(s) of deposit being purchased this day by Mizuho Bank, Ltd., as Account Bank and bailee on behalf of the Security Trustee and the other Secured Parties. 

  
 -44- 

 § 4.3(a)(i) 

 

	 	4.3	Accounts 

  

	 	(a)	The Company has established and maintains, and shall from time to time, including as required under this Agreement, establish and maintain (or cause the Account Bank to establish and maintain), in the name of the
Company, the following segregated, secured, and non-interest-bearing accounts and any related sub-accounts (the “Accounts”): 

 

	 	(i)	one or more Loan Facility Disbursement Accounts into which disbursements of Loans shall be paid in accordance with Section 4.5(a) (Deposits and Withdrawals – Disbursements of Senior Debt);

  

	 	(ii)	if Senior Notes are issued, one or more Senior Note Disbursement Accounts (including any Senior Notes proceeds escrow account used for the purposes described in Section 4.5(a)(iii) (Deposits and Withdrawals
– Disbursements of Senior Debt – Disbursements of Senior Debt – Escrow of Senior Notes Issued as Replacement Senior Debt)) (the “Senior Note Disbursement Accounts”) into which the proceeds of the
sale of Senior Notes shall be paid in accordance with Section 4.5(a) (Deposits and Withdrawals – Disbursements of Senior Debt); 

  

	 	(iii)	an Equity Proceeds Account, into which Cash Flow received prior to the Project Completion Date and Equity Funding shall be deposited in accordance with Section 4.5(b) (Deposits and Withdrawals
– Equity Proceeds Account); 

  

	 	(iv)	a Construction Account, into which Equity Funding or Senior Debt received by the Securing Parties shall be deposited in accordance with Section 4.5(c) (Deposits and Withdrawals –
Construction Account); 

  

	 	(v)	a Revenue Account, into which Cash Flows and other income, revenues and proceeds received by or on behalf of the Securing Parties shall be deposited in accordance with Section 4.5(d) (Deposits and
Withdrawals – Revenue Account); 

  

	 	(vi)	an Operating Account, established and operated as provided in Section 4.5(e) (Deposits and Withdrawals – Operating Account); 

 

	 	(vii)	a Senior Debt Service Reserve Account, established and operated as provided in Section 4.5(i) (Deposits and Withdrawals – Senior Debt Service Reserve Account); 

 

	 	(viii)	Expansion Accounts (if any), established and operated as provided in Section 4.5(k) (Deposits and Withdrawals – Expansion Accounts); 

 

	 	(ix)	an Insurance/Condemnation Proceeds Account, established and operated as provided in Section 4.5(f) (Deposits and Withdrawals – Insurance/Condemnation Proceeds Account); 

 

	 	(x)	a Mandatory Prepayment Senior Notes Account (if required), established and operated as provided in Section 4.5(j) (Deposits and Withdrawals – Mandatory Prepayment Senior Notes Account);

  
 -45- 

 § 4.3(a)(xi) 

 

	 	(xi)	an Additional Proceeds Prepayment Account, established and operated as provided in Section 4.5(g) (Deposits and Withdrawals – Additional Proceeds Prepayment Account); 

 

	 	(xii)	[Reserved]; and 

  

	 	(xiii)	a Permitted Finance Costs Reserve Account, established and operated as provided in Section 4.5(l) (Deposits and Withdrawals – Permitted Finance Costs Reserve Account). 

 

	 	(b)	Each Account shall be maintained with the Account Bank in the United States and shall be denominated in US Dollars. 

  

	 	(c)	In respect of such Accounts: 

  

	 	(i)	Each Account may include one or more sub-accounts established and maintained by the Company, subject to the process in sub-clause
(ii) below. References in this Agreement to an Account shall apply equally to any sub-account under such Account and the restrictions and the Company’s obligations under this Agreement with respect
to any sub-account shall be the same as its restrictions and obligations with respect to the associated Account. The Security Trustee shall have the same rights with respect to a
sub-account as the associated Account. 

  

	 	(ii)	Without prejudice to the other requirements of this Section 4.3 (Accounts), it is acknowledged by each party that although this Agreement refers to sub-accounts
required or permitted to be maintained with the Account Bank, each such sub-account shall be a separate account (with its own unique number) and any reference to any such
sub-account shall be construed accordingly. The sub-accounts shall be established and managed as follows: 

 

	 	(A)	the Company shall give the Security Trustee and the Account Bank at least 10 days’ prior written notice (commencing from the date when all information and forms required by
sub-clause (B) below have been provided) of any sub-accounts that the Company intends to establish and maintain; 

 

	 	(B)	as a condition to the establishment of any additional sub-account, the Company shall provide or complete any customary information or forms required by the Account Bank;

  

	 	(C)	each sub-account shall be identified with the particular Account to which it relates and shall be segregated from each other sub-account;
and 

  

	 	(D)	each sub-account shall be secured in the same manner as the Accounts and withdrawals and transfers to and from each sub-account and any
investments of cash or other properties and assets therein shall be subject to the same provisions of this Agreement as the principal Account associated with such sub-account. 

  
 -46- 

 § 4.3(c)(ii)(D) 

 

	 	(d)	As of the date hereof, the Company has opened the Accounts described in sub-clauses (a)(i) above and one of each of the Accounts described in
sub-clauses (a)(iii), (iv), (v), (vi), (vii), (viii), (ix), (xi), (xii) and (xiii) above. The Company shall at a later date instruct the Account Bank to open any of the other Accounts described in clause
(a) above as and when such Account is needed by the Company. The subsequent (i.e., after the date hereof) Accounts shall be established and managed as follows: 

 

	 	(i)	the Company shall give the Security Trustee and the Account Bank at least 10 days’ prior written notice (commencing from the date when all information and forms required by
sub-clause (ii) below have been provided) of any Account that the Company intends to establish and maintain; and 

  

	 	(ii)	as a condition to the establishment of any additional Account, the Company shall provide or complete any customary information or forms required by the Account Bank. 

 

	 	4.4	Procedures for Deposits and Withdrawals from Accounts 

  

	 	(a)	The following procedures shall apply to withdrawals and transfers of monies from the Accounts: 

  

	 	(i)	the Company shall not be entitled to request withdrawals or transfers of monies from any Account without having provided a Withdrawal and Transfer Certificate authorizing such withdrawal and/or transfer;
provided, that a Withdrawal and Transfer Certificate shall not be required for any of the Accounts to be managed as set forth in clause (d)(ii) below; 

  

	 	(ii)	each Withdrawal and Transfer Certificate shall request withdrawals and transfers to and from Accounts in accordance with Section 4.5 (Deposits and Withdrawals). 

 

	 	(b)	The Withdrawal and Transfer Certificate shall: 

  

	 	(i)	be delivered to the Security Trustee and Account Bank (A) if delivered prior to the Project Completion Date, at least two Business Days prior to any withdrawal or transfer from any Account requested by the Company
(or the same Business Day in the case of the Second Phase Closing Date or the date of the Initial Advance) and (B) if delivered on or after the Project Completion Date, at least three Business Days prior to any withdrawal or transfer from any
Account requested by the Company; 

  
 -47- 

 § 4.4(b)(ii) 

 

	 	(ii)	be duly executed by an authorized signatory of the Company (including any Person so authorized by the Manager) who has been identified on a duly executed incumbency certificate or other written instructions showing the
names, titles and specimen signatures of the Persons authorized to act on behalf of the Company (including any Person so authorized by the Manager) to take actions and provide certifications as required hereunder, including the execution and
delivery of any Withdrawal and Transfer Certificate; and 

  

	 	(iii)	contain the following information: 

  

	 	(A)	each Account from which a withdrawal or transfer is requested and, for transfers, the relevant Account(s) to which, and/or other Person(s) to whom, such transfer is to be made; 

 

	 	(B)	the amount requested to be withdrawn or transferred from each Account; 

  

	 	(C)	the relevant date on which such withdrawal or transfer is to be made; and 

  

	 	(D)	the purpose for which the amount so withdrawn or transferred is to be applied (if not evident from the nature of the payment or identity of the intended payee). 

 

	 	(c)	If, prior to the relevant date of withdrawal or transfer, the Security Trustee reasonably believes that a Withdrawal and Transfer Certificate contains an error, the Security Trustee may (but shall have no obligation to
do so unless otherwise instructed in accordance with any Finance Documents) object to such withdrawal or transfer by notifying the Company and the Account Bank in writing, following which the Company may make any corrections. If no objections are
made, or if the error to which an objection relates to has been corrected, the Account Bank shall pay or transfer the amount(s) specified in the previously received Withdrawal and Transfer Certificate or the corrected Withdrawal and Transfer
Certificate, as applicable, by making such payment or transfer no later than the close of business New York time on the date set out in such Withdrawal and Transfer Certificate for such payment, transfer or requested authorization thereof as
applicable; provided that if the Account Bank does not receive the corrected certificate at least one Business Day prior to such date of withdrawal or transfer or requested authorization thereof, the Account Bank shall pay or transfer the
amount(s) specified by the close of business New York time on the next succeeding Business Day following delivery of such Withdrawal and Transfer Certificate to the Account Bank (except for corrected Withdrawal and Transfer Certificates delivered on
the Second Phase Closing Date or the date of Initial Advance, which shall be paid or a transfer shall be made on the same Business Day as receipt). 

  
 -48- 

 § 4.4(d) 

 

	 	(d)	The Company may enter into an e-banking, or other similar agreement, with the Account Bank to enable the Company to directly manage withdrawals from the Accounts through on-line access (including by electronic wire transfer). 

  

	 	(i)	Other than for the Accounts to be managed as set forth in sub-clause (ii) below, the procedures set forth in clause (a) above shall apply to all Accounts for which the
Company enters into an agreement contemplated by this clause (d). 

  

	 	(ii)	In the case of the Equity Proceeds Account, the Disbursement Accounts, the Permitted Finance Costs Reserve Account and the Operating Account, the Company may establish such Accounts with the Account Bank within a system
enabling the Company to directly manage withdrawals from such Account (including by electronic wire transfer). For the avoidance of doubt, a Withdrawal and Transfer Certificate shall not be required for withdrawals or transfers from any account for
which a system is established pursuant to this sub-clause (ii). 

  

	 	4.5	Deposits and Withdrawals 

  

	 	(a)	Disbursements of Senior Debt 

  

	 	(i)	All disbursements of Senior Debt shall be paid directly (x) to a Loan Facility Disbursement Account in the case of the Loans (which may include separate Loan Facility Disbursement Accounts if required under the
individual Facility Agreement) or (y) to a Senior Note Disbursement Account in the case of any Senior Notes; provided that: 

  

	 	(A)	except for disbursements for the purpose of (i) paying interest and commitment fees during the Availability Period (which shall be disbursed in accordance with Section 2.01(e) (Term Loans) of the Term
Loan Facility Agreement), (ii) the payment of financing costs (including closing costs, upfront fees, original issue discount and other fees and expenses, commissions and discounts payable) to Facility Lenders, purchasers or underwriters of Senior
Notes in each case in connection with the incurrence of Senior Debt, (iii) Mobilization Payments (as defined in the EPC Contract (T3)) made on or about the Second Phase Closing, and (iv) disbursements used to fund the Senior Debt Service
Reserve Account or otherwise to be paid as set forth in Section 2.7 (Senior Debt/Equity Ratio at Project Completion Date) of the Common Terms Agreement, the Initial Senior Debt shall be disbursed directly into the Construction Account;

  
 -49- 

 § 4.5(a)(i)(B) 

 

	 	(B)	any Senior Debt may be disbursed directly into the Construction Account or used directly to pay Permitted Development Expenditures or for other purposes as are permitted in the Senior Debt Instrument for such Senior
Debt (including, for the avoidance of doubt, by transferring amounts of Senior Debt to another Account, such as the Operating Account, prior to application of the Senior Debt to the purpose for which it is permitted to be applied if such Account is
generally used by the Securing Parties to pay such amounts); 

  

	 	(C)	Senior Debt drawn for the purposes set forth in Section 2.7 (Senior Debt/Equity Ratio at Project Completion Date) of the Common Terms Agreement may be applied directly for the purposes set forth in
Section 2.7 (Senior Debt/Equity Ratio at Project Completion Date) of the Common Terms Agreement; 

  

	 	(D)	any disbursements of Replacement Senior Debt may be applied, in each case as permitted by each Senior Debt Instrument then in effect, directly to repay the Senior Debt that such Replacement Senior Debt is replacing and
for other purposes for which such Replacement Senior Debt is permitted to be used under the Finance Documents; and 

  

	 	(E)	Working Capital Debt may be applied directly for the purposes for which it was incurred (including, for the avoidance of doubt, by transferring amounts of Senior Debt to another Account, such as the Operating Account,
prior to application of the Senior Debt to the purpose for which it is permitted to be applied if such Account is generally used by the Securing Parties to pay such amounts). 

 

	 	(ii)	The Company shall apply the proceeds of any disbursement of Senior Debt in accordance (A) in the case of the Initial Senior Debt, with the purposes permitted in Section 12.1 (Use of Proceeds) of the
Common Terms Agreement and (B) otherwise as permitted in the relevant Senior Debt Instrument. 

  

	 	(iii)	Disbursements of Senior Debt – Escrow of Senior Notes Issued as Replacement Senior Debt 

  

	 	(A)	Notwithstanding any other provision in the Finance Documents, with respect to any Replacement Senior Debt incurred pursuant to the issuance of Senior Notes under any Indenture, the Company may at its option hold the
proceeds of such Indebtedness in a Senior Note Disbursement Account in escrow for not more than a 30-day escrow period for the purpose of effecting the Senior Debt replacement. 

  
 -50- 

 § 4.5(a)(iii)(B) 

 

	 	(B)	In connection with such escrow arrangements, the Company shall have the right, at any time prior to the end of the escrow period, to deposit cash and/or Authorized Investments into the Senior Note Disbursement Account
using funds available in the Permitted Finance Costs Reserve Account or at the fourth level of the cash waterfall pursuant to Section 4.7(a)(iv) (Cash Waterfall) to pay (1) the transaction fees and expenses related to the
Senior Note issuance and escrow arrangement and (2) interest that is due in respect of the escrowed amount from the date of the deposit until the end of the escrow period or the date the escrowed amount is withdrawn from the Senior Note
Disbursement Account, whichever is earlier. 

  

	 	(iv)	Such Senior Note Disbursement Account shall be subject to a Lien pursuant to Section 3.2(c)(ii) (Security Interests to be Granted by the Securing Parties – Security Interests – Individual Senior
Noteholder Secured Accounts) solely for the benefit of the Senior Noteholders who purchase such Senior Notes (and not any other Senior Creditors); provided that such proceeds shall be used only to either effect a disbursement of
Replacement Senior Debt and repay existing Senior Debt or to repay the relevant Senior Noteholders at the end of the relevant escrow period. 

  

	 	(A)	During the relevant escrow period such Senior Noteholders shall not have recourse to the Security Interests, the Securing Parties or any assets of the Company (including the Project Property) in respect of repayment of
such Indebtedness, other than in respect of the security granted over the applicable Senior Notes Disbursement Account into which the proceeds of such issuance are paid. 

 

	 	(B)	For the avoidance of doubt, during the relevant escrow period, the proceeds of any such Senior Notes held in such Senior Notes Disbursement Account shall not be counted as Indebtedness for the purposes of determining
any ratio under the Common Terms Agreement (including any ratios required to be met as a condition to the incurrence of such Replacement Senior Debt) and the Company shall not be in breach of any undertakings set forth in Article 12 (Loan Party
Covenants) of the Common Terms Agreement or trigger any Loan Facility Event of Default solely as a result of the arrangements contemplated in sub-clause (iii) (Disbursements of Senior Debt –
Escrow of Senior Notes Issued as Replacement Senior Debt) and this sub-clause (iv). 

  

	 	(b)	Equity Proceeds Account 

  

	 	(i)	 Until the Project Completion Date, Equity Funding and all other Cash Flow and all other income, revenues and
proceeds received by or on behalf of the Securing Parties and not required to be deposited into another Account (other than Business Interruption Insurance Proceeds and Delay Liquidated Damages) received by the Securing Parties shall be deposited in
the Equity Proceeds Account; provided that (A) any portion of the 

  
 -51- 

 § 4.5(b)(i) 

 

	 	
Equity Funding to be used for payment of any fees and expenses concurrently with the signing of any Finance Documents, Second Phase Closing or Initial Advance of Senior Debt, may be paid directly
to the Secured Party entitled thereto pursuant to the terms of the applicable Finance Documents, (B) amounts in the Equity Proceeds Account may be transferred directly to the Construction Account to be used in accordance with clause (c)
(Construction Account) below, (C) Equity Funding may be deposited directly into the Construction Account to be used in accordance with clause (c) (Construction Account) below and (D) amounts in the Equity Proceeds Account may
be used to make Restricted Payments (including Non-Base Case Restricted Payments) if the conditions for Restricted Payments under Section 11.3 (Additional Restricted Payments) of the Common Terms
Agreement and any comparable provision in any Senior Debt Instrument then in effect are satisfied. 

  

	 	(ii)	On the Project Completion Date, funds held on deposit in the Equity Proceeds Account shall, subject to Section 4.4 (Procedures for Deposits and Withdrawals from Accounts), be transferred to the Construction
Account to be distributed in accordance with clause (c) (Construction Account) below. 

  

	 	(iii)	Following the Project Completion Date, Equity Funding not otherwise committed to other expenditure for the Development may be deposited into the Equity Proceeds Account for transfer into the Construction Account, an
Expansion Equity Proceeds Account or Expansion Construction Account for application towards Permitted Development Expenditures or otherwise in connection with the Development; provided, that the Company may deposit Equity Funding into an
Expansion Equity Proceeds Account in accordance with clause (k) (Expansion Accounts) below. 

  

	 	(c)	Construction Account 

  

	 	(i)	The Company may, from time to time, deposit Equity Funding and Senior Debt proceeds directly into the Construction Account (which may be deposited directly or transferred from the Equity Proceeds Account or a
Disbursement Account, as applicable). 

  

	 	(ii)	Until the Project Completion Date, the Company may, from time to time, deposit into the Construction Account Business Interruption Insurance Proceeds and Delay Liquidated Damages. 

 

	 	(iii)	Funds in the Construction Account shall be used for Project Costs and, prior to the Project Completion Date, may be used to pay any and all Operation and Maintenance Expenses either directly or by transferring such
funds to the Operating Account (subject, in the case of Senior Debt, to the limitations on application towards Operation and Maintenance Expenses set forth in the definition of Project Costs). 

  
 -52- 

 § 4.5(c)(iii) 

 

	 	(iv)	On the Project Completion Date, after leaving sufficient funds in the Construction Account to cover the Permitted Completion Amount, funds remaining in the Construction Account shall, subject to Section 4.4
(Procedures for Deposits and Withdrawals from Accounts), be transferred to the Senior Debt Service Reserve Account, and any funds remaining after the Senior Debt Service Reserve Account is fully funded up to the then-applicable Reserve Amount
(if such funds were sufficient to fully fund such Senior Debt Service Reserve Account) shall then be transferred to the Revenue Account. 

  

	 	(v)	Following the Project Completion Date, funds in the Construction Account may be used for Permitted Completion Costs. If the Company fails to withdraw or transfer funds to pay Permitted Completion Costs, the Security
Trustee is hereby authorized, but shall not be obligated, to direct, in writing, the Account Bank to transfer or withdraw amounts from the Construction Account necessary to pay Permitted Completion Costs that are, from time to time, due and payable
and are not in dispute. 

  

	 	(vi)	Following the Project Completion Date, Equity Funding allocated by the Company for Permitted Development Expenditures, proceeds of PDE Senior Debt, and other amounts permitted to be used for Permitted Development
Expenditures and allocated by the Company for such expenditures shall be deposited into the Construction Account or any Expansion Construction Account for application towards Permitted Development Expenditures or may be used directly to pay for
Permitted Development Expenditures. 

  

	 	(vii)	Following the Project Completion Date, the Construction Account may (but need not) be closed at the determination of the Company after all Permitted Completion Costs have been paid and all funds therein have been
transferred first to the Senior Debt Service Reserve Account until fully funded up to the then-applicable Reserve Amount and second to the Revenue Account. If such Account is closed as set forth herein by providing written notice to
the Account Bank, the Company may subsequently re-establish an account that is designated as the Construction Account if required for any of the expenditures described in
sub-clause (vi) above upon satisfaction of the requirements in Sections 4.3(d)(i) and (ii) (Accounts) above. 

  

	 	(d)	Revenue Account 

  

	 	(i)	Following the Project Completion Date, all Cash Flows and all other income, revenues and proceeds (including Delay Liquidated Damages and Business Interruption Insurance Proceeds) received by or on behalf of the
Securing Parties, and not required to be deposited into another Account, shall be paid into the Revenue Account. 

  
 -53- 

 § 4.5(d)(i) 

 

	 	(ii)	Funds shall be withdrawn from the Revenue Account as provided in Section 4.7 (Cash Waterfall) and Section 4.8 (Accounts During the Continuance of a Declared Event of Default). 

 

	 	(e)	Operating Account 

  

	 	(i)	The Operating Account shall be funded, prior to the Project Completion Date, from the Construction Account and, on and after the Project Completion Date, as provided in Section 4.7 (Cash Waterfall) and
Section 4.8 (Accounts During the Continuance of a Declared Event of Default) and shall be used to pay Operation and Maintenance Expenses of the Securing Parties that are due and in a manner consistent with the obligations of the Securing
Parties under the Finance Documents then in effect. In addition to the foregoing, Senior Debt proceeds that are permitted to be used to pay Operation and Maintenance Expenses under the terms of the applicable Senior Debt Instrument may be funded
directly, or from a Disbursement Account, into the Operating Account. 

  

	 	(ii)	The Company will use commercially reasonable efforts to limit transfers made to the Operating Account to twice per month, if required and requested by the Account Bank, in order to accommodate the operations of the
Account Bank. 

  

	 	(f)	Insurance/Condemnation Proceeds Account 

  

	 	(i)	Insurance Proceeds, Condemnation Proceeds and Performance Liquidated Damages received by any Securing Party shall be deposited in the Insurance/Condemnation Proceeds Account. 

 

	 	(ii)	Net Cash Proceeds (other than proceeds from asset sales permitted under the Senior Debt Instruments, including Section 12.17 (Sale of Project Property) of the Common Terms Agreement) shall be deposited into
the Insurance/Condemnation Proceeds Account and may be transferred to the Additional Proceeds Prepayment Account if required as set forth in sub-clause (g)(ii) below. 

 

	 	(iii)	Amounts in the Insurance/Condemnation Proceeds Account shall, subject to Section 4.4 (Procedures for Deposits and Withdrawals from Accounts), be applied for the purposes set forth in and in accordance with
Section 5.2 (Insurance and Condemnation Proceeds). 

  
 -54- 

 § 4.5(g)(i) 

 

	 	(g)	Additional Proceeds Prepayment Account 

  

	 	(i)	Performance Liquidated Damages shall be transferred from the Insurance/Condemnation Proceeds Account to the Additional Proceeds Prepayment Account in accordance with Section 5.3(c) (Performance Liquidated
Damages) to make a mandatory prepayment pursuant to any Senior Debt Instrument (including Section 3.4(a)(ii) (Mandatory Prepayments – Performance Liquidated Damages) of the Common Terms Agreement). 

 

	 	(ii)	Net Cash Proceeds (other than proceeds from asset sales permitted under the Senior Debt Instruments, including Section 12.17 (Sale of Project Property) of the Common Terms Agreement) shall be deposited in or
transferred to the Additional Proceeds Prepayment Account when required to be used to make mandatory prepayments pursuant to Section 3.4(a)(vii) (Mandatory Prepayments – Net Cash Proceeds from the Sale of Project Property) of
the Common Terms Agreement. 

  

	 	(iii)	Amounts from an escrow account under the EPC Contracts shall be transferred to the Additional Proceeds Prepayment Account in accordance with clause (h) (EPC Escrow Account) below when required to be used to make
a mandatory prepayment in accordance with Section 3.4(a)(iii) (Mandatory Prepayments – Escrowed Amounts) of the Common Terms Agreement. 

  

	 	(iv)	Any amount remaining on deposit in the Additional Proceeds Prepayment Account in excess of a required mandatory prepayment may be transferred to the Revenue Account. 

 

	 	(h)	EPC Escrow Account 

  

	 	(i)	Any amount remaining on deposit in an escrow account under the EPC Contracts after the Project Completion Date shall be transferred by the Company to the Additional Proceeds Prepayment Account to make a mandatory
prepayment pursuant to Section 3.4(a)(iii) (Mandatory Prepayments – Escrowed Amounts) of the Common Terms Agreement if required therein or otherwise transferred to the Revenue Account. 

 

	 	(i)	Senior Debt Service Reserve Account 

  

	 	(i)	Within six months following the Project Completion Date and otherwise in accordance with Section 4.7 (Cash Waterfall) or Section 4.8 (Accounts During the Continuance of a Declared Event of
Default), the Company shall cause the Senior Debt Service Reserve Account to be funded up to the then-applicable Reserve Amount, from funds in the Construction Account in accordance with Section 4.5(c)(iv) (Construction Account)
above, funds received pursuant to Section 2.7 (Senior Debt/Equity Ratio at Project Completion Date) of the Common Terms Agreement or directly from other Cash Flows in accordance with Section 4.7 (Cash Waterfall) or
Section 4.8 (Accounts During the Continuance of a Declared Event of Default) and/or Equity Funding. 

  
 -55- 

 § 4.5(i)(ii) 

 

	 	(ii)	Prior to making any Restricted Payments and on any Payment Date following the date that is six months after the Project Completion Date, to the extent there is a Senior Debt Reserve Shortfall, the Securing Parties shall
transfer to the Senior Debt Service Reserve Account from the Revenue Account in accordance with the fifth level of priority as set forth in Section 4.7 (Cash Waterfall), an amount equal to such Senior Debt Reserve Shortfall. Other
than in respect of the requirement set forth in sub-clause (i) above, the Securing Parties shall not be obligated to make any such Senior Debt Reserve Shortfall payment to the extent the balance of the
Revenue Account is insufficient to make such payment and the failure to make the full amount of such Senior Debt Reserve Shortfall payment, to such extent and in the circumstances described in this sub-clause
(ii), shall not itself constitute an Event of Default. The Company shall give the Security Trustee and the Intercreditor Agent prompt notice if less than 100% of the then-applicable Reserve Amount has been deposited in the Senior Debt Service
Reserve Account on or prior to the applicable date. 

  

	 	(iii)	Funds in the Senior Debt Service Reserve Account may be replaced by an Acceptable Debt Service Reserve LC. 

  

	 	(iv)	The Senior Debt Service Reserve Account shall be used to pay Senior Debt Obligations then due if there would otherwise be no funds available in the Revenue Account to meet such Senior Debt Obligations in accordance with
the priority set forth in Section 4.7 (Cash Waterfall). 

  

	 	(v)	Funds in the Senior Debt Service Reserve Account in excess of the Reserve Amount may be transferred to the Revenue Account. 

  

	 	(j)	Mandatory Prepayment Senior Notes Account 

  

	 	(i)	The Company shall be entitled to establish a segregated account or accounts, if so required under any Indenture, that are secured solely for the benefit of Senior Noteholders and into which such Senior Noteholders’
pro rata share of a mandatory prepayment may be deposited rather than paid to such Senior Noteholders, any such account a “Mandatory Prepayment Senior Notes Account.” Such deposits shall be retained in such
Mandatory Prepayment Senior Notes Account during the pendency of any related mandatory redemption offer in respect of any Senior Notes and as otherwise may be required during the tenor of such Senior Notes, in each case for prepayment of the
applicable Senior Notes to the extent required by the terms of the relevant Indenture, as applicable. The establishment of any such Mandatory Prepayment Senior Notes Account shall be subject to satisfaction of the requirements in Sections 4.3(d)(i)
and (ii) (Accounts) above. 

  
 -56- 

 § 4.5(j)(ii) 

 

	 	(ii)	Only the Senior Noteholders (or their Senior Creditor Group Representative) of the applicable Senior Debt Obligation secured by a Mandatory Prepayment Senior Notes Account may direct the Security Trustee with respect to
such Mandatory Prepayment Senior Notes Account. 

  

	 	(k)	Expansion Accounts 

 The Securing Parties may establish “Expansion Disbursement
Accounts”, “Expansion Equity Proceeds Accounts” and “Expansion Construction Accounts” as follows, in each case subject to satisfaction of the requirements in Sections 4.3(d)(i) and (ii) (Accounts) above: 

 

	 	(i)	The Company may deposit Equity Funding (which shall be in addition to any Equity Funding contemplated in the Base Case Forecast for any Train then under construction), into an Expansion Equity Proceeds Account or an
Expansion Construction Account to fund (directly or through a transfer from the Expansion Equity Proceeds Account to the Expansion Construction Account): 

  

	 	(A)	front-end engineering, development and design work, early works or pre-construction activities; 

 

	 	(B)	preparation and submission for Permits related to any such expansion; or 

  

	 	(C)	Permitted Development Expenditures. 

  

	 	(ii)	When permitted under the Senior Debt Instruments (including Section 7.2 (Expansion Contracts) of the Common Terms Agreement), the Company may deposit Equity Funding, which is in addition to the Equity
Funding contemplated in the Base Case Forecast in connection with the development of the first three Trains, into an Expansion Equity Proceeds Account or an Expansion Construction Account (directly or through a transfer from the Expansion Equity
Proceeds Account to the Expansion Construction Account) to fund an Expansion. 

  

	 	(iii)	Upon the incurrence of any Expansion Senior Debt, the Company may deposit such Expansion Senior Debt into an Expansion Disbursement Account for transfer into an Expansion Construction Account to fund an Expansion.

  

	 	(iv)	After completion of an Expansion, the Company shall transfer funds from the Expansion Construction Account to the Revenue Account in a manner similar to such transfer in relation to the construction of the initial
Project Facilities. 

  
 -57- 

 § 4.5(k)(v) 

 

	 	(v)	Deposits and withdrawals of funds from the Expansion Disbursement Accounts, Expansion Equity Proceeds Accounts and Expansion Construction Accounts with respect to the Expansion shall be made consistent with the terms
set forth herein for deposits and withdrawals of funds for Disbursement Accounts, Equity Proceeds Accounts and Construction Accounts, respectively, with appropriate changes to reflect the terms of the Expansion. 

 

	 	(l)	Permitted Finance Costs Reserve Account 

  

	 	(i)	The Permitted Finance Costs Reserve Account shall be funded in accordance with Section 4.7 (Cash Waterfall) or Section 4.8 (Accounts During the Continuance of a Declared Event of Default) and
shall be used to pay Permitted Finance Costs of the Securing Parties as and when such amounts may be due and payable from time to time in accordance with the Company’s regular payment procedures. 

 

	 	(ii)	Amounts on deposit in the Permitted Finance Costs Reserve Account may be invested in Authorized Investments. 

  

	 	4.6	Control and Investment of Funds in Accounts 

  

	 	(a)	Unless the Security Trustee has received notice as set out in Section 6.1(b) (Security Trustee Action Generally – Control of Accounts) that a Loan Facility Declared Default, Indenture Declared
Default or any other Declared Event of Default has occurred and is Continuing, and until a notice is delivered to the Account Bank pursuant to clause (b) below, the Company shall have the sole right to take the following actions (on the terms
and subject to the conditions and requirements hereof), including, when required, pursuant to the instruction to the Account Bank: 

  

	 	(i)	to withdraw and transfer any funds in the Accounts in accordance with Section 4.7 (Cash Waterfall) and the other Sections of this Agreement, including in each case subject to the satisfaction of
Section 4.4 (Procedures for Deposits and Withdrawals from Accounts); and 

  

	 	(ii)	to invest any funds in the Accounts in Authorized Investments (and from time to time to direct the variation or redemption of any such investments), in each case subject to the requirements of Section 4.2
(Authorized Investments). 

  

	 	(b)	If a Loan Facility Declared Default, Indenture Declared Default or any other Declared Event of Default has occurred and is Continuing and notification of such event has been provided in accordance with
Section 6.1(b) (Security Trustee Action Generally – Control of Accounts): 

  
 -58- 

 § 4.6(b)(i) 

 

	 	(i)	the Security Trustee shall deliver a notice to the Account Bank (with a copy to the Company and each Senior Creditor Group Representative) directing it to cease accepting instructions from, and providing management
access to, the Company (and, if relevant, from the Manager to whom the Company has granted a power of attorney or signature authority over the Accounts as permitted under Section 4.1(e) (General Principles)) with respect to the Accounts
(including with respect to the withdrawal, transfer and investment of funds (and any variation or redemption of such investments)) and to accept instructions solely from the Security Trustee; and 

 

	 	(ii)	following delivery of such notice, the Security Trustee shall direct the Account Bank to: 

  

	 	(A)	apply the funds in the Accounts in accordance with Section 4.8 (Accounts During the Continuance of a Declared Event of Default); and 

 

	 	(B)	invest any funds in the Accounts only in Authorized Investments (at the risk and the expense of the Company); provided that the Security Trustee is hereby authorized to direct the Account Bank to liquidate any
investment to the extent that after application of all other funds, liquidation of such investment is necessary to make such withdrawal or transfer and the Security Trustee shall use its reasonable efforts to direct the Account Bank in liquidating
investments in a manner that minimizes interest costs and penalties, 

 in each case until (1) such Declared Event of
Default is no longer Continuing and the Security Trustee has received a Cessation Notice or (2) a Security Enforcement Action has been initiated in accordance with this Agreement, and the Security Trustee has been otherwise instructed by
Security Enforcement Action Initiation Requests sufficient to take Security Enforcement Action or the Security Enforcement Action Representative in accordance with Section 6.3 (Conduct of Security Enforcement Action) and written notice
thereof has been provided by the Security Trustee to the Account Bank. 
 Without affecting the generality of any other exculpatory
provisions in this Agreement or other Finance Documents, neither the Security Trustee (as such hereunder) nor the Account Bank shall have any liability with respect to any withdrawal or investments of funds in the Accounts made pursuant to this
Section 4.6 (Control and Investment of Funds in Accounts), unless arising from its own gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in a final and
non-appealable judgment. 
  

	 	(c)	 The Company irrevocably authorizes the Account Bank to comply with any notice delivered by the Security Trustee
pursuant to sub-clause (b)(i) above even if the Company objects to them in any way, and agrees that the Account Bank 

  
 -59- 

 § 4.6(c) 

 

	 	
may apply any funds in the Accounts in accordance with such instructions. Company further agrees that after the Account Bank receives a notice from the Security Trustee pursuant to sub-clause (b)(i) above, the Company shall not have access to, and shall not be entitled to instruct the Security Trustee or the Account Bank with respect to, any Accounts or the funds and Authorized
Investments credited thereto. 

  

	 	(d)	Upon the receipt of a Cessation Notice relating to all outstanding Declared Events of Default, the Security Trustee shall deliver a notice to the Account Bank with a copy to the Company directing it once again to take
instructions from the Company in accordance with clause (a) above rather than exclusively from the Security Trustee. 

  

	 	(e)	The Account Bank shall not, under any circumstances: 

  

	 	(i)	be responsible for any loss, cost or expense suffered by any Person in respect of any actions in relation to the acquisition, disposal, deposit or delivery of the Authorized Investments other than for its own gross
negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in a final and non-appealable judgment; or 

 

	 	(ii)	have any obligation to advise the Company on, or to select, manage, investigate or monitor, any Authorized Investments or the purchase or sale thereof. 

 

	 	(f)	All documents of title or other documentary evidence of ownership with respect to the Authorized Investments shall be held in the custody of the Account Bank, or, if a Declared Event of Default has occurred and is
Continuing, and the Security Trustee so directs, if any such document or other evidence is then in or thereafter comes into the possession or control of the Account Bank, the Account Bank shall deliver the same to the Security Trustee. If any
documents of title or other documentary evidence of ownership with respect to the Authorized Investments comes into the possession and/or control of the Company, the Company shall immediately hand over such documents to the custody of the Account
Bank or, if a Declared Event of Default has occurred and is Continuing, and the Security Trustee so directs, the Security Trustee. 

  

	 	(g)	 The Company and the Security Trustee agree that, as between the Company and the Security Trustee on the one hand
and the Account Bank on the other, other than for its own gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in a final and non-appealable judgment, the Account
Bank shall have no responsibility whatsoever to ensure that the amounts deposited in and withdrawn from the Accounts are deposited or withdrawn in accordance with the terms of this Agreement. For the avoidance of doubt, the Company and, solely to
the extent that it has taken control of and continues to control the Accounts as permitted hereunder, the Security Trustee shall be responsible for ensuring that the amounts deposited in and withdrawn from the

  
 -60- 

 § 4.6(g) 

 

	 	
Accounts are deposited or withdrawn in accordance with the terms of this Agreement. As between the Account Bank and the other Parties, the Company shall be solely responsible for its own filing
(or causing the filing) of tax returns and reports on any transaction in respect of any Authorized Investments or relating to any Authorized Investment as may be required by any Governmental Authority or by any authority of any other nation or
government or a state or other political subdivision thereof. 

  

	 	(h)	Any reference in this Agreement to “the Company or the Security Trustee, as the case may be” or words of similar effect means the Company, when it is entitled to give instructions pursuant to clauses
(a) and (c) above, and the Security Trustee, when, during the Continuance of a Declared Event of Default, the Account Bank has been instructed to cease accepting instructions from the Company. 

 

	 	4.7	Cash Waterfall 

  

	 	(a)	Unless a Loan Facility Declared Default, Indenture Declared Default or any other Declared Event of Default occurred and is Continuing, pursuant to Section 4.6(a) (Control and Investment of Funds in
Accounts), the Company may request or instruct the Account Bank, at the following times, to withdraw funds from the Revenue Account and, where contemplated below, the Senior Debt Service Reserve Account, and shall procure that such funds be
applied in the following order of priority and solely for the following purposes: 

  

	 	(i)	first, from time to time, to transfer to the Operating Account for the payment of Operation and Maintenance Expenses: 

  

	 	(A)	the sum of (1) all Operation and Maintenance Expenses then due and unpaid, if any, and (2) Operation and Maintenance Expenses reasonably estimated at the time of such transfer by the Company to become
due and payable in accordance with the Company’s regular payment procedures within the next 60 days; less 

  

	 	(B)	any funds in respect of such Operation and Maintenance Expenses that are on deposit in the Operating Account (including its sub-accounts) and available for the payment of
Operation and Maintenance Expenses; 

  

	 	(ii)	second, from time to time, for Secured Party Fees then due and payable to the Secured Parties pursuant to any Finance Document; 

 

	 	(iii)	third, on a Payment Date, for payments of Senior Debt Obligations then due and payable (other than Senior Debt Obligations expressly payable at a higher or lower level of the cash waterfall pursuant to this
Section 4.7(a) (Cash Waterfall)) on a pro rata basis to all Senior Creditors entitled thereto (to the extent not funded from funds available in a Disbursement Account or by “book entry” under a Facility Agreement);

  
 -61- 

 § 4.7(a)(iii)(A) 

 

	 	(A)	the order of payments of Senior Debt Obligations shall be: 

  

	 	(1)	first, for interest payments and costs due and payable on the Senior Debt Obligations and scheduled payments pursuant to Permitted Hedging Instruments that are secured by Security Interests and rank
pari passu with the Senior Debt Obligations; 

  

	 	(2)	second, for scheduled principal payments on the Senior Debt Obligations and Hedging Termination Amounts payable pursuant to Permitted Hedging Instruments that are secured by the Security Interests and rank
pari passu with the Senior Debt Obligations; and 

  

	 	(3)	third, for payment of any other Senior Debt Obligations due and payable; 

  

	 	(B)	such payments shall be made: 

  

	 	(1)	first, from the Revenue Account; and 

  

	 	(2)	second, from the Senior Debt Service Reserve Account (to the extent of any deficiency in funds available in the Revenue Account); 

 

	 	(iv)	fourth, from time to time, for Permitted Finance Costs then due and payable; provided that such payments shall also be subject to clause (c) below; 

 

	 	(v)	fifth, on any Payment Date following the date that is six months after the Project Completion Date and on any date on which a Restricted Payment is made, to satisfy any Senior Debt Reserve Shortfall by
making a transfer to the Senior Debt Service Reserve Account; 

  

	 	(vi)	sixth, on a Payment Date, for any mandatory prepayments under any Senior Debt Instrument not payable out of a specific Account that are then due and payable and excluding any mandatory prepayments pursuant to
Section 3.4(a)(viii) (Mandatory Prepayments – Restricted Payments) of the Common Terms Agreement; 

  

	 	(A)	the order of payments shall be: 

  

	 	(1)	first, for any mandatory prepayments made on a pro rata basis to all the Senior Creditors; and 

  

	 	(2)	second, for any individual mandatory prepayments payable on a non-pro rata basis, 

  
 -62- 

 § 0 
  

 including, in each case, any Permitted Hedging Liabilities associated with such prepayments;

  

	 	(vii)	seventh, from time to time for any Permitted Payment; provided that such payments shall also be subject to clause (c) below; 

 

	 	(viii)	eighth, from time to time, to make voluntary prepayments of Loans or voluntary redemptions of any Senior Notes, including Permitted Hedging Liabilities associated with such prepayments, in each case in accordance
with the Senior Debt Instruments then in effect (including Section 3.5 (Voluntary Prepayment) of the Common Terms Agreement); provided that such payments shall also be subject to clause (c) below; and 

 

	 	(ix)	ninth, to make other payments as and when permitted by the Finance Documents, including for deposit into the Equity Proceeds Account or into the Expansion Equity Proceeds Account or for Restricted Payments if, in
each case, the conditions for Restricted Payments under each Senior Debt Instrument (including Section 11.1 (Conditions to Restricted Payments) of the Common Terms Agreement and any comparable provision in any Senior Debt Instrument then
in effect) are satisfied; provided that if the circumstances set forth in Section 3.4(a)(viii) (Mandatory Prepayments – Restricted Payments) of the Common Terms Agreement apply on any Quarterly Payment Date, payments
shall be made at this level of the waterfall as set forth in Section 3.4(a)(viii) (Mandatory Prepayments – Restricted Payments) of the Common Terms Agreement. 

 

	 	(b)	With respect to each level and sub-level of the cash waterfall set forth in clause (a) above, if the amount available for payment of Senior Debt Obligations required to be
paid at such level or sub-level of the cash waterfall, is insufficient to pay all amounts then required to be paid, such payments shall be made on a pari passu, pro rata basis to
the applicable Secured Parties entitled to a payment at such level or sub-level of the cash waterfall. The Withdrawal and Transfer Certificate provided in respect of any such payment shall specify the pro
rata allocation to be made by the Account Bank to the applicable Secured Parties. 

  

	 	(c)	For so long as any Loans under the Term Loan Facility Agreement are outstanding and subject to Section 4.4 (Procedures for Deposits and Withdrawals from Accounts): 

 

	 	(i)	 the payment of Permitted Finance Costs pursuant to the fourth level of the cash waterfall under clause
(a)(iv) above shall be made only on a CTA Payment Date; provided that on any CTA Payment Date, after payment of any Permitted Finance Costs that are due and payable on such date, the Company may, at its sole discretion, transfer funds into
the Permitted Finance Costs Reserve Account such that the Permitted Finance Costs Reserve Account has amounts on deposit therein equal to any Permitted Finance Costs reasonably estimated at the time of such transfer by the

  
 -63- 

 § 4.7(c)(i) 

 

	 	
Company to become due and payable in accordance with the Company’s regular payment procedures prior to the next occurring CTA Payment Date and, for the avoidance of doubt, the restrictions
set forth in Section 4.7(a) shall not apply to withdrawal of funds from the Permitted Finance Costs Reserve Account to pay such Permitted Finance Costs as and when they become due and payable as set forth in Section 4.5(l) (Deposits and
Withdrawals – Permitted Finance Costs Reserve Account); 

  

	 	(ii)	the payment of Permitted Payments pursuant to the seventh level of the cash waterfall under clause (a)(vii) above shall be made only on a CTA Payment Date; and 

 

	 	(iii)	any voluntary prepayment of Loans or voluntary redemption of any Senior Notes, and payment of related Senior Debt Obligations, pursuant to the eighth level of the cash waterfall under clause (a)(viii) above shall
be made only on a CTA Payment Date; provided that, for the avoidance of doubt, voluntary prepayments or voluntary redemptions made with proceeds of Replacement Senior Debt shall not be subject to this timing requirement and may be paid
directly from such proceeds or from funds in the applicable Disbursement Account. 

  

	 	4.8	Accounts During the Continuance of a Declared Event of Default 

  

	 	(a)	If a Loan Facility Declared Default, Indenture Declared Default or any other Declared Event of Default has occurred and notification of such event has been provided to the Security Trustee and prior to any Enforcement
Action, subject to and in accordance with Section 4.6(b) (Control and Investment of Funds in Accounts) and Section 4.6(c) (Control and Investment of Funds in Accounts), the Security Trustee shall cause the available funds in
the Accounts (other than the Insurance/Condemnation Proceeds Account) to be applied in accordance with the order of priority in the first to sixth levels of priority in the waterfall in Section 4.7 (Cash Waterfall) above.

  

	 	(b)	During the Continuation of a Declared Event of Default, the Company shall deliver to the Security Trustee and the Independent Engineer at least 10 Business Days prior to the beginning of each calendar month a
certificate setting forth its good faith estimate of the amount of Restricted Operation and Maintenance Expenses that are expected to become due and payable during such calendar month. The Security Trustee shall direct the application of funds in
the Secured Accounts (other than the Insurance/Condemnation Proceeds Account) by delivery of a written instruction to the Account Bank, as provided in such certificate unless, within eight Business Days after its delivery, the Independent Engineer,
by written notice to the Security Trustee with a copy to the Company, objects to the proposed application set forth in such certificate in which case funds shall be applied to Restricted Operation and Maintenance Expenses as reasonably specified in
writing by the Independent Engineer. 

  
 -64- 

 § 4.9(a) 

 

	 	(c)	With respect to each level and sub-level of the cash waterfall set forth in clause (a) above, if the amount available for payment of Senior Debt Obligations required to be
paid at such level or sub level of the cash waterfall is insufficient to pay all amounts then required to be paid, such payments shall be made on a pari passu, pro rata basis to the applicable Secured Parties entitled to a payment at
such level or sub-level of the cash waterfall. 

  

	 	4.9	Acceptable Debt Service Reserve LC 

  

	 	(a)	The Company or a direct or indirect parent company of the Company (including the Sponsor) may cause to be delivered to the Security Trustee an Acceptable Debt Service Reserve LC instead of, or to replace, the cash or
Authorized Investments deposited in or credited to the Senior Debt Service Reserve Account at any time. When an Acceptable Debt Service Reserve LC is delivered to the Security Trustee to replace cash or Authorized Investments already deposited in
the Senior Debt Service Reserve Account, the replaced cash or Authorized Investments shall be transferred directly to the parent company providing such Acceptable Debt Service Reserve LC or, if the Company has provided such Acceptable Debt Service
Reserve LC, to any Account designated by the Borrower, upon the satisfaction of the conditions in and pursuant to clause (c) below. For the avoidance of doubt, the Company may procure such Acceptable Debt Service Reserve LC under any Working
Capital Debt or other Indebtedness permitted to be incurred by the Loan Parties under the Finance Documents. 

  

	 	(b)	The Person(s) providing the Acceptable Debt Service Reserve LC shall provide the Security Trustee notice in writing at least 10 Business Days before the date on which the Acceptable Debt Service Reserve LC is to be
provided and such notice shall include a final draft of the proposed Acceptable Debt Service Reserve LC and the stated (face) amount of such Acceptable Debt Service Reserve LC. 

 

	 	(c)	Following provision of the notice referred to in clause (b) above, if the following conditions are satisfied: 

  

	 	(i)	the Acceptable Debt Service Reserve LC satisfies the requirements of the definition thereof; 

  

	 	(ii)	the Person(s) providing such Acceptable Debt Service Reserve LC has provided the original Acceptable Debt Service Reserve LC to the Security Trustee; and 

 

	 	(iii)	no Event of Default has occurred and is Continuing; 

 such Acceptable Debt Service Reserve LC
shall be deemed to be deposited in the Senior Debt Service Reserve Account in an amount equal to the face (stated) amount of such Acceptable Debt Service Reserve LC and, if cash and/or Authorized Investments had already been deposited in the Senior
Debt Service Reserve Account and such Acceptable Debt Service Reserve LC is being provided to replace such cash and/or Authorized Investments, the Account Bank 

  
 -65- 

 § 4.9(d) 

 

 
shall, subject to Section 4.4 (Procedures for Deposits and Withdrawals from Accounts), transfer to (or as directed by) the Person(s) providing such Acceptable Debt Service Reserve LC
from the Senior Debt Service Reserve Account an amount of cash and/or Authorized Investments equal to the amount of the Acceptable Debt Service Reserve LC on the later of (x) the date on which such Person(s) has delivered originals of all
documents meeting the requirements set forth herein (and substantially consistent with the draft provided under clause (b) above) and (y) the effective date of the Acceptable Debt Service Reserve LC. 

 

	 	(d)	The Security Trustee shall be allowed to draw down an Acceptable Debt Service Reserve LC, without consent from any other Person, and deposit the proceeds thereof into the Senior Debt Service Reserve Account (or,
following the initiation of Security Enforcement Action in accordance with this Agreement, into such other account identified by the Security Trustee) if: 

  

	 	(i)	it is not renewed or replaced with cash from the provider(s) thereof of equivalent value or other Acceptable Debt Service Reserve LC or if the Security Trustee has not received notice from the issuing bank of such
Acceptable Debt Service Reserve LC that it shall extend the expiration date or renew it, in each case by at least 30 days prior to its expiration date; 

  

	 	(ii)	the entity issuing the Acceptable Debt Service Reserve LC is downgraded and no longer qualifies as an Acceptable Bank and the provider(s) thereof does not, within 15 days following such downgrade, either replace such
issuing entity with an Acceptable Bank or replace the Acceptable Debt Service Reserve LC with Authorized Investments or cash (which may be cash provided by the provider(s) thereof or from Restricted Payments that the Company is entitled to make or
the provider(s) of such Acceptable Debt Service Reserve LC is entitled to receive); 

  

	 	(iii)	the letter of credit otherwise fails to qualify as an Acceptable Debt Service Reserve LC and is not replaced with another Acceptable Debt Service Reserve LC, Authorized Investments or cash (which may be cash provided by
the provider(s) thereof or from Restricted Payments that the Company is entitled to make or the provider(s) of such Acceptable Debt Service Reserve LC is entitled to receive); 

 

	 	(iv)	to pay any amount that may be paid from the Senior Debt Service Reserve Account pursuant to Section 4.5(i) (Deposits and Withdrawals – Senior Debt Service Reserve Account); 

 

	 	(v)	the entity issuing the Acceptable Debt Service Reserve LC does not provide its consent to a transfer of such Acceptable Debt Service Reserve LC to a replacement Security Trustee and such Acceptable Debt Service Reserve
LC is not replaced prior to the resignation or removal of the Security Trustee in accordance with Section 8.7 (Resignation, Removal and Replacement of Security Trustee) becoming effective; 

  
 -66- 

 § 4.9(d)(vi) 

 

	 	(vi)	without any limitation on the Security Trustee’s right and power to draw on the Acceptable Debt Service Reserve LC in accordance with this clause (d), unless a Declared Event of Default is Continuing, the Company
shall be entitled to request the Security Trustee to draw down such Acceptable Debt Service Reserve LC at any time and deposit cash from such drawdown into the Senior Debt Service Reserve Account, whereupon the Security Trustee shall promptly comply
with such request; provided that, in the event of any conflict between the requirements of the other sub-clauses of this clause (d) and any request pursuant to this
sub-clause (vi), the requirements of the other sub-clauses shall prevail and control; and 

 

	 	(vii)	without limiting any of the foregoing, at any time following delivery of a Notice of Security Enforcement Action by the Security Trustee pursuant to Section 6.2(f) (Initiation of Security Enforcement Action
– Notice of Security Enforcement Action). 

  

	 	(e)	Subject to Sections 8.1(a) and (b) (Appointment and Duties), 8.20(b) (Compliance) and any other provision of this Agreement relating to the Security Trustee’s exercising its rights, powers and
discretions hereunder, if any issuer of any Acceptable Debt Service Reserve LC fails to make payment when due following a demand from the Security Trustee, the Security Trustee shall, unless prevented by applicable law, and without prejudice to the
provisions of Article 8 (The Security Trustee), pursue its remedies against such defaulting issuer to the extent permitted by the terms of the applicable Acceptable Debt Service Reserve LC. For the avoidance of doubt, payments received
by the Security Trustee under an Acceptable Debt Service Reserve LC pursuant to the pursuit by the Security Trustee of remedies against a defaulting issuer under this clause shall be (A) first, applied to pay Senior Debt Obligations then
due and unpaid to the extent there would otherwise be insufficient funds available from the Revenue Account to meet the Senior Debt Obligations then due and unpaid and (B) second, to the extent any excess remains, deposited into the
Senior Debt Service Reserve Account. 

  

	 	(f)	Once provided, the Acceptable Debt Service Reserve LC shall be maintained for the benefit of the Senior Debt Service Reserve Account except to the extent that: 

 

	 	(i)	the Acceptable Debt Service Reserve LC is replaced with cash and/or Authorized Investments or with Restricted Payments that the Company is entitled to make or that the provider is entitled to receive; 

 

	 	(ii)	the Acceptable Debt Service Reserve LC is fully drawn by the Security Trustee in accordance with clause (d) above; or 

  
 -67- 

 § 4.9(f)(iii) 

 

	 	(iii)	the Acceptable Debt Service Reserve LC (or any part thereof) is replaced with another Acceptable Debt Service Reserve LC, cash and/or Authorized Investments in accordance with clause (g) below. 

 

	 	(g)	A Person providing an Acceptable Debt Service Reserve LC may, upon five Business Days’ prior written notice to the Security Trustee replace (in whole or in part) on a dollar-for-dollar basis any Acceptable Debt Service Reserve LC procured by it with (A) another Acceptable Debt Service Reserve LC or (B) cash for deposit and/or Authorized Investments for credit
into the Senior Debt Service Reserve Account, which shall be cash and/or Authorized Investments provided by the provider(s) thereof or from Restricted Payments that the Company is entitled to make or the provider(s) of such Acceptable Debt Service
Reserve LC is entitled to receive. 

 Upon delivery to the Security Trustee of the new Acceptable Debt Service Reserve LC or
delivery to the Account Bank of cash for deposit and/or Authorized Investments for credit into the Senior Debt Service Reserve Account as provided in this clause (g) in an amount equal to the face (stated) amount of the replaced Acceptable Debt
Service Reserve LC, the Security Trustee shall return to the relevant provider thereof the Acceptable Debt Service Reserve LC and related documents so replaced in full. 
  

	 	(h)	Upon any changes to the amount, status or nature of any Acceptable Debt Service Reserve LC, including: 

  

	 	(i)	the transfer of cash and/or Authorized Investments from the Senior Debt Service Reserve Account to the provider of the Acceptable Debt Service Reserve LC upon the provision of any Acceptable Debt Service Reserve LC in
accordance with clause (c) above; 

  

	 	(ii)	the cancellation, return or drawdown of any Acceptable Debt Service Reserve LC, in each case in accordance with the terms of this Agreement (including pursuant to any of the events described in clause (f) above);
or 

  

	 	(iii)	any replacement of any Acceptable Debt Service Reserve LC with another Acceptable Debt Service Reserve LC, cash and/or Authorized Investments or any change to the entity providing such Acceptable Debt Service Reserve
LC, 

 the Security Trustee shall notify the Senior Creditor Group Representatives. 

 

	 	4.10	Adequate Instruction; Sufficiency of Funds 

  

	 	(a)	 Notwithstanding anything to the contrary contained in this Agreement, in the event that the Account Bank receives
any monies in respect of any Securing Party or the Development without adequate instruction as to the Account into which such monies are to be deposited, the Account Bank shall promptly deposit such monies into (i) on or prior to the Project
Completion Date, the Construction 

  
 -68- 

 § 4.10(a) 

 

	 	
Account (for purposes of this sentence, the Project Completion Date shall be deemed to have occurred at such time as the Security Trustee so notifies the Account Bank in writing, which notice the
Security Trustee shall promptly deliver upon the occurrence of the Project Completion Date), and (ii) thereafter, the Revenue Account, keeping such records as may be necessary to adequately distinguish such monies from other funds held in such
Account, and shall immediately thereafter notify the Company and the Security Trustee of the receipt of such monies. Upon written instruction from the Company, unless the Security Trustee has received notice as set out in Section 6.1(b)
(Security Trustee Action Generally – Control of Accounts) that a Loan Facility Declared Default, Indenture Declared Default or any other Declared Event of Default has occurred and is Continuing, the Security Trustee or the Account
Bank (if applicable) shall transfer any such monies to the corrected Account specified by the Company or the Security Trustee in a written notice delivered to the Account Bank. 

 

	 	(b)	Notwithstanding anything to the contrary contained in this Agreement, to the extent that there are insufficient funds in the relevant Account to make a payment, transfer or withdrawal requested from such Account, the
Account Bank shall promptly notify the Security Trustee and the Company of such deficiency. In such event, the Account Bank shall make such payment, transfer or withdrawal to the extent of the available funds in the specified Account unless it has
received written instructions not to make such payment from the Security Trustee (or the Company, unless the Security Trustee has received notice as set out in Section 6.1(b) (Security Trustee Action Generally – Control of
Accounts) that a Loan Facility Declared Default, Indenture Declared Default or any other Declared Event of Default has occurred and is Continuing). 

  

	 	4.11	Account with Third Party Account Bank 

 Notwithstanding any other provision of this
Agreement, including Section 4.3(a) and (b) (Accounts), Sections 4.4 (Procedures for Deposits and Withdrawals from Accounts) and Section 3.2(d)(vi) (Accounts – Securities Accounts): 

 

	 	(a)	The Company may from time to time agree to establish and maintain a segregated, secured account, which shall be an Account, and any related sub-accounts (the “Third Party
Investment Account”) with any financial institution that is reasonably acceptable to the Account Bank (any financial institution that is not the Account Bank with which such account is established as permitted by this Agreement, a
“Third Party Account Bank”); provided that the Company shall procure that prior to the deposit or transfer of any funds into such Third Party Investment Account: 

 

	 	(i)	such Third Party Account Bank shall enter into an account control agreement in form and substance reasonably satisfactory to the Security Trustee, pursuant to which the Security Trustee shall have sole
“control” (within the meaning of Sections 8-106(d) and (f) of the UCC or Sections 9-104(a)(2) and (3) of the UCC) of the Third Party Investment
Account; 

  
 -69- 

 § 4.10(a)(ii) 

 

	 	(ii)	the Account Bank shall be designated as an authorized representative of the Borrower permitted to execute transactions and make withdrawals and transfers of funds in respect of such Third Party Investment Account; and

  

	 	(iii)	the Third Party Investment Account may be interest bearing. 

  

	 	(b)	The Company (or the Security Trustee on behalf of the Company) may submit instructions (in written form, including in a Withdrawal and Transfer Certificate from the Company, and which may be given as a standing
instruction) to the Account Bank directing the Account Bank to take the following actions in respect of the Third Party Investment Account: 

  

	 	(i)	transfer funds from an Account to the Third Party Investment Account or instruct the Third Party Account Bank to transfer funds from the Third Party Investment Account to one or more Accounts, or 

 

	 	(ii)	instruct the Third Party Account Bank to invest funds in the Third Party Investment Account in Authorized Investments selected as set forth in clause (e) below (or sell or otherwise liquidate such investments) as
contemplated by Section 4.2(b) (Directing the Making of Investments – Authorized Investments), in a manner agreed between the Company and the Third Party Account Bank in any customary account management agreement related to the
Third Party Investment Account, 

 and, in each such case, the Account Bank shall act in accordance with the instructions of
the Company (or the Security Trustee on behalf of the Company) and in turn transmit any such instructions to the Third Party Account Bank. For the avoidance of doubt, the Company (or the Security Trustee on behalf of the Company) shall be permitted
to transfer funds from any Account, including but not limited to the Construction Account, Revenue Account and/or the Operating Account, to be held in the Third Party Investment Account until such funds are required to be applied as contemplated by
this Agreement, and shall be permitted to transfer such funds back to the applicable Account at any earlier time. 
  

	 	(c)	 Unless the Security Trustee has received notice as set out in Section 6.1(b) (Security Trustee Action
Generally – Control of Accounts) that a Loan Facility Declared Default, Indenture Declared Default or any other Declared Event of Default has occurred and is Continuing, and until a notice is delivered to the Account Bank pursuant to
Section 4.6(b)(i) (Control and Investment of Funds in Accounts), the Company also may submit instructions directly (or by instructions made through the Account Bank) to the Third Party Account Bank to invest the funds in, or that are
expected to be transferred into, the Third Party Investment Account in Authorized Investments. Concurrently with delivery of a notice to the Account Bank pursuant to Section 4.6(b)(i) (Control and Investment of Funds in Accounts), the
Security Trustee shall deliver a notice to the Third Party Account Bank (with a copy to the Company, the Account Bank and each Senior Creditor Group Representative) directing it to cease accepting instructions from, and

  
 -70- 

 § 4.11(c) 

 

	 	
providing management access to, the Company (and, if relevant, from the Manager to whom the Company has granted a power of attorney or signature authority over the Accounts as permitted under
Section 4.1(e) (General Principles)) with respect to the Third Party Investment Account. Concurrently with delivery of a notice to the Account Bank pursuant to Section 4.6(d) (Control and Investment of Funds in Accounts), the
Security Trustee shall deliver a notice to the Third Party Account Bank with a copy to the Company directing it once again to take instructions from the Company in accordance with the first sentence of this clause (c) rather than exclusively
from the Security Trustee. 

  

	 	(d)	If the Account Bank receives a notice from the Security Trustee under Section 4.6(b)(i) (Control and Investment of Funds in Accounts) of this Agreement, the Security Trustee may deliver instructions directly
to the Third Party Account Bank or may direct the Account Bank to transmit to the Third Party Account Bank directions, notices or other documents received only from the Security Trustee until a notice is delivered by the Security Trustee to the
Account Bank pursuant to and in accordance with Section 4.6(d) (Control and Investment of Funds in Accounts) of this Agreement with respect to the relevant Declared Event(s) of Default. 

 

	 	(e)	All funds in the Third Party Investment Account shall only be invested in Authorized Investments as selected by the Company (or the Security Trustee on behalf of the Company). Cash, monies or funds in the Third Party
Investment Account and the Authorized Investments in which such monies are then invested and the proceeds of those investments shall be subject to the provisions of this Agreement governing Authorized Investments, including but not limited to
Section 4.2 (Authorized Investments), modified as necessary to reflect the arrangements between the Company, the Security Trustee, the Account Bank and the Third Party Account Bank as set forth in this Section 4.11.

  

	 	(f)	For the avoidance of doubt, the security arrangements generally applicable to Accounts pursuant to this Agreement shall also apply to the Third Party Investment Account, with the Third Party Account Bank acting as Bank
or Securities Intermediary, as applicable, in respect of the Third Party Investment Account. All undertakings and duties imposed on the Account Bank specifically in its capacity as Bank or Securities Intermediary in respect of an Account shall also
apply in respect of any Third Party Investment Account, except that the Account Bank shall be subject to such duties and undertakings in its capacity as an authorized person in respect of such Third Party Investment Account. All duties or
undertakings under the Finance Documents requiring the Account Bank to deposit, withdraw, invest or liquidate funds in the Accounts shall, in respect of the Third Party Investment Account, be construed as duties or undertakings to instruct the Third
Party Account Bank to deposit, withdraw, invest or liquidate funds, as applicable. 

  

	 	(g)	The Account Bank shall not be liable for any failure on the part of the Third Party Account Bank to timely honor any direction from the Account Bank. 

  
 -71- 

 § 5.2(b) 

 

	5.	INSURANCE AND CONDEMNATION PROCEEDS AND PERFORMANCE LIQUIDATED DAMAGES 

  

	 	5.1	Additional Insureds 

  

	 	(a)	To the extent permitted under applicable laws and regulations, from and after the Second Phase Closing Date, the Company shall procure that, under all insurance policies purchased by the Securing Parties (other than any
title insurance policies, terrorism insurance (from any statutory terrorism scheme) or other statutory insurance and except to the extent otherwise specified in Schedule L (Schedule of Minimum Insurance) of the Common Terms Agreement and any
comparable provision in any Senior Debt Instrument then in effect): 

  

	 	(i)	the Secured Parties and/or the Security Trustee on behalf of and for the benefit of the Secured Parties shall be named as additional insureds and the interest of the Secured Parties shall be duly noted and endorsed upon
all cover notes and policies issued or to be issued in connection therewith; 

  

	 	(ii)	the Security Trustee shall be a loss payee (other than in respect of third party liability insurance and automobile liability insurance) and such loss payable clause shall not be cancelled, varied or amended in any
respect; 

  

	 	(iii)	all such policies shall require insurers (and brokers), subject to applicable laws and regulations and to the payment procedures under Attachment O of the Applicable EPC Contracts, to pay the proceeds (other than
payments due to third parties) to the Insurance/Condemnation Proceeds Account; and 

  

	 	(iv)	the Company shall provide to the Security Trustee the notices required pursuant to Section 10.7 (Insurance Reporting) of the Common Terms Agreement and any other comparable provision in a Senior Debt
Instrument. 

  

	 	5.2	Insurance and Condemnation Proceeds 

 Insurance Proceeds and Condemnation Proceeds
received by any Securing Party shall be applied as follows: 
  

	 	(a)	sums paid to settle any third-party liability shall be paid to the Person who incurred the liability (or to the insured party if such party previously paid the claim); 

 

	 	(b)	Business Interruption Insurance Proceeds will be deposited in the Revenue Account and applied in accordance with Section 4.7 (Cash Waterfall); 

 

	 	(c)	all other Insurance Proceeds and Condemnation Proceeds shall be deposited in the Insurance/Condemnation Proceeds Account; provided that for the period prior to the Project Completion Date, the first $10,000,000
in Insurance Proceeds under the builder’s risk insurance policy or marine cargo policy shall be paid directly to the EPC Contractor; 

  
 -72- 

 § 5.2(c) 

 

	 	(d)	all Insurance Proceeds and Condemnation Proceeds deposited in the Insurance/Condemnation Proceeds Account shall be transferred to the Revenue Account and applied in accordance with Section 4.7 (Cash
Waterfall); provided that if the aggregate amount of the Insurance Proceeds or Condemnation Proceeds for a single loss or related series of losses: 

  

	 	(i)	is less than $75,000,000, such proceeds shall be transferred from the Insurance/Condemnation Proceeds Account directly for use to repair or replace the relevant Project Property (or, unless the Insurance Proceeds and
Condemnation Proceeds are required for the repair or replacement, to reimburse documented amounts contributed to or paid on behalf of the affected Securing Party by the Sponsor or a parent company of the Company for purposes of commencing any such
repair or replacement) unless the Company certifies that failure to repair or replace such Project Property shall not reduce the annual production capacity or the Project Facilities’ performance to a level below that which is necessary to meet
its then outstanding Senior Debt Obligations, in which case such proceeds shall be transferred to the Revenue Account; 

  

	 	(ii)	exceeds $75,000,000 but is less than $500,000,000, then such proceeds shall be applied in accordance with clause (e) below; and 

 

	 	(iii)	exceeds in the aggregate $500,000,000, then such proceeds shall be applied in accordance with clause (f) below; provided that: 

 

	 	(A)	the provisions of clause (g) below (and not clause (f) below) shall apply in the event of a Catastrophic Casualty Event resulting in a mandatory prepayment offer of the Senior Notes, to the extent an Indenture
providing for such a prepayment upon a Catastrophic Casualty Event is then outstanding; and 

  

	 	(B)	if no Loans are outstanding at the time, then clause (e) below (and not clause (f) below) shall apply in respect of Insurance Proceeds or Condemnation Proceeds that exceed in the aggregate $500,000,000 in the
case where the event giving rise to such proceeds is not a Catastrophic Casualty Event resulting in a mandatory prepayment offer of the Senior Notes; 

  

	 	(e)	proceeds required to be applied in accordance with this clause (e) shall be: 

  

	 	(i)	 transferred from the Insurance/Condemnation Proceeds Account directly to repair or replace the relevant Project
Facilities (or, unless the Insurance Proceeds and Condemnation Proceeds are required for the repair or replacement, to reimburse documented amounts contributed to or paid on behalf of the affected Securing Party by the Sponsor or a parent company

  
 -73- 

 § 5.2(e)(i) 

 

	 	
of the Company for purposes of commencing any such repair or replacement) upon receipt by the Security Trustee of a certificate as set forth below and a Withdrawal and Transfer Certificate to the
Account Bank confirming such certificate has been provided to the Security Trustee: 

  

	 	(A)	the Company, certifying that: 

  

	 	(1)	such transferred proceeds shall be used to repair or replace the relevant Project Facilities; 

  

	 	(2)	such repair or replacement is expected to maintain the annual production capacity and the Project Facilities’ performance in all material respects; 

 

	 	(3)	the affected Securing Party has sufficient funds available (including Cash Flow permitted to be applied under Section 4.7 (Cash Waterfall) towards repair and replacement of Project Facilities, Equity
Funding commitments and amounts in the Insurance/Condemnation Proceeds Account) to repair or replace the relevant Project Facilities according to a restoration plan in order to carry out its obligations under this
sub-clause (A) as well as to pay all Operation and Maintenance Expenses, Senior Debt Obligations and any other expenditure that is, or is reasonably likely to be, due to be paid during the period of
repair and replacement; 

  

	 	(4)	such repair or replacement shall be completed within 180 days (plus up to an additional 90 days if the affected Securing Party is exercising commercially reasonable efforts to complete the improvements, repairs and
restorations (and if the Project Completion Date has not yet occurred, by no later than the Date Certain); 

  

	 	(5)	any Permits necessary for the repair or replacement have been obtained and are in full force and effect or are expected to be obtained in the ordinary course by the time they are necessary; and 

 

	 	(B)	the Independent Engineer confirming (such confirmation not to be unreasonably withheld) its concurrence with the certification made pursuant to sub-clause (A)(2) above;

  

	 	(ii)	 if the Company or the Independent Engineer fails to make any of the certifications or concurrences required by sub-clause (i) above by 90 days after the deposit in the Insurance/Condemnation Proceeds Account of the relevant Insurance Proceeds or Condemnation Proceeds, or to the extent

  
 -74- 

 § 5.2(f)(i)(A) 

 

	 	
there are any excess Insurance Proceeds or Condemnation Proceeds remaining in the Insurance/Condemnation Proceeds Account after the completion of a restoration undertaken in compliance with sub-clause (i) above and such excess proceeds exceed $75,000,000, such proceeds shall be applied (A) in accordance with Section 3.4(a)(i) (Mandatory Prepayments – Insurance and Condemnation
Proceeds) of the Common Terms Agreement to prepay Loans pro rata based on the respective outstanding principal amounts thereof on the respective Payment Dates for payment of principal for such Senior Debt immediately succeeding such 90-day period, (B) to pay the portion of such amount equal to the pro rata share of the Senior Debt held by Senior Noteholders as specified in the applicable Indenture and (C) with respect to paying
all remaining proceeds, to the Revenue Account. For the avoidance of doubt, the Senior Noteholders (if any) shall have no right to waive or alter the foregoing prepayment obligation other than in respect of amounts due to such Senior Noteholders
under sub-clause (B) above; 

  

	 	(f)	

  

	 	(i)	For so long as the Loans are outstanding, on or before 90 days following the receipt in the Insurance/Condemnation Proceeds Account of proceeds required to be applied in accordance with this clause (f), the Company
shall deliver to the Security Trustee and Intercreditor Agent the certification described in sub-clause (e)(i)(A) above and a plan for the application of such proceeds and other funds available to the
affected Securing Party for the repair or replacement of the relevant Project Facilities. The Company shall include in such plan: 

  

	 	(A)	a schedule of works required to complete the repair or replacement; 

  

	 	(B)	the estimated costs associated with such repair or replacement; 

  

	 	(C)	a list of the material contracts entered into or to be entered into to effect the repair or replacement; 

  

	 	(D)	a detailed account of the sources of funds; 

  

	 	(E)	the scheduled completion date for the repair and/or replacement works; and 

  

	 	(F)	a schedule showing each Senior Debt Obligation payable through such scheduled completion date for repair and/or replacement showing the source of funds (available Cash Flow, Equity Funding, insurance proceeds, committed
financings and/or any other resource reasonably acceptable to the Intercreditor Agent) for each such payment. 

  
 -75- 

 § 5.2(f)(ii) 

 

	 	(ii)	As soon as reasonably practicable, but in any event within 60 days following receipt of such plan, if the Security Trustee (based on instruction from the Intercreditor Agent) notifies the Company (which notification
shall be accompanied by a reasonably detailed explanation) that the Requisite Intercreditor Parties conclude in their reasonable judgment (taking into account the advice, if any, of the Independent Engineer) that, in light of the nature of the loss,
the reasonableness of the plan and the amount of Senior Debt Obligations then outstanding: 

  

	 	(A)	it is reasonably unlikely that, after implementation of the Company’s plan and any ramp up or similar period, the Company shall be able to meet its Senior Debt Obligations; or 

 

	 	(B)	it is reasonably likely that, after implementation of the Company’s plan and any ramp up or similar period, a Material Adverse Effect shall occur, 

then the Company shall apply such proceeds on a pro rata basis (I) in accordance with Section 3.7 (Pro Rata
Payment) of the Common Terms Agreement to prepay the Senior Debt held by the Facility Lenders pro rata based on the respective outstanding principal amounts thereof on the respective Payment Dates for payments of principal for such
Senior Debt immediately succeeding such 60-day period, (II) to pay the portion of such amount equal to the pro rata share of the Senior Debt held by Senior Noteholders as specified in the
applicable Indenture and (III) with respect to all remaining proceeds, to the Revenue Account. For the avoidance of doubt, the Senior Noteholders (if any) shall have no right to waive or alter the foregoing prepayment obligation other than in
respect of amounts due to such Senior Noteholders under sub-clause (II) above; 
  

	 	(g)	Notwithstanding the foregoing provisions of this Section 5.2 (Insurance and Condemnation Proceeds), in the event of a Catastrophic Casualty Event resulting in a mandatory prepayment offer of the Senior Notes
in accordance with the terms of the applicable Indenture, the Company shall make a pro rata mandatory prepayment of the Loans in an amount equal to the amount proportionate to the principal amount of Senior Notes outstanding that is being
prepaid pursuant to such Catastrophic Casualty Event mandatory prepayment offer. 

  

	 	(h)	 Nothing in this Section 5.2 (Insurance and Condemnation Proceeds) shall preclude the Company from
using equity to commence repairs or to replace property subject to such loss prior to receipt of Insurance Proceeds or Condemnation Proceeds. In such circumstances, nothing shall prevent the Securing Parties from applying the Insurance Proceeds or
Condemnation Proceeds received and that are not required for the repair and replacement of property to reimburse documented amounts contributed to or paid on behalf of the affected Securing Party by the Sponsor or a parent company of the Company for
purposes of commencing any such repair or replacement to the extent that such 

  
 -76- 

 § 5.2(h) 

 

	 	
Insurance Proceeds or Condemnation Proceeds could have been applied toward the repair and replacement directly according to this Section 5.2 (Insurance and Condemnation Proceeds)
(provided that such reimbursed amounts are applied for such purpose) and provided, further, that reimbursement shall not be permitted to the extent that Insurance Proceeds and Condemnation Proceeds were insufficient for repair
or replacement and such equity was certified as necessary to undertake such repair or replacement). 

  

	 	(i)	No later than 45 days following the end of each calendar quarter (beginning the first calendar quarter following the commencement of any repair or replacement carried out in connection with a loss for which the
Insurance Proceeds or Condemnation Proceeds exceed $75,000,000 and ending the calendar quarter during which such repair or replacement is completed), the Company shall deliver to the Security Trustee, the Intercreditor Agent and the Independent
Engineer a summary of the construction activities required in connection with any repair or replacement of the affected Project Facilities carried out during such calendar quarter. Such summary shall include a description of: 

 

	 	(i)	the physical progress and expenditures during such calendar quarter; 

  

	 	(ii)	cumulative expenditures through to the end of such calendar quarter; 

  

	 	(iii)	material variations in physical progress and expenditures from the plan, together with a summary description of the causes of such variations, and any steps or actions intended to be taken to minimize such variances in
the future; 

  

	 	(iv)	the Company’s then-current estimates of: 

  

	 	(A)	expenditures for the next quarter; and 

  

	 	(B)	the then-scheduled completion date for such works; and 

  

	 	(v)	any material developments during such quarter relating to the relevant repair or replacement. 

  

	 	(j)	Any insurance proceeds that are not required by this Section 5.2 (Insurance and Condemnation Proceeds) and by the relevant provisions of any Senior Debt Instruments to be used for the repair and replacement
of the affected Project Property (or to reimburse documented amounts contributed to or paid on behalf of the affected Securing Party by the Sponsor or a parent company of the Company for purposes of commencing any such repair or replacement if such
amounts are not required for the repair and replacement of property) or that are not required for the mandatory prepayment of any Senior Debt Obligations (including by transfer of the amount of the Pro Rata Payment to prepay Senior Debt held by
Senior Creditors other than the Facility Lenders that would otherwise have been made as a prepayment to such Senior Creditors to a Mandatory Prepayment Senior Notes Account), in accordance with this Section 5.2 (Insurance and Condemnation
Proceeds) or the relevant provisions of any Senior Debt Instruments, shall be transferred to the Revenue Account and applied in accordance with Section 4.7 (Cash Waterfall). 

  
 -77- 

 § 6.1(a)(i) 

 

	 	5.3	Performance Liquidated Damages 

 Performance Liquidated Damages received by any Securing
Party shall be applied as follows: 
  

	 	(a)	to complete, repair, refurbish or improve the Project Facilities in respect of which the Performance Liquidated Damages were paid or other Project Facilities under construction related to the Corpus Christi Terminal
Facility or the Corpus Christi Pipeline; 

  

	 	(b)	to repay or reimburse providers of Equity Funding to the extent such Equity Funding was used to complete, repair, refurbish or improve the Project Facilities in respect of which the Performance Liquidated Damages were
paid or other Project Facilities under construction related to the Corpus Christi Terminal Facility or the Corpus Christi Pipeline; and 

  

	 	(c)	if at any time Performance Liquidated Damages not used in accordance with clause (a) or (b) above within 180 days following receipt thereof (or 270 days if a commitment to complete, repair, refurbish or improve the
Project Facilities is entered within 180 days following the receipt of such proceeds) meet the criteria for making a mandatory prepayment pursuant to any Senior Debt Instrument (including Section 3.4(a)(ii) (Mandatory Prepayments –
Performance Liquidated Damages) of the Common Terms Agreement), then the required amount shall be transferred to the Additional Proceeds Prepayment Account and applied to such mandatory prepayment. 

 

	6.	SECURITY TRUSTEE ACTION 

  

	 	6.1	Security Trustee Action Generally 

  

	 	(a)	Action under Individual Senior Debt Instruments and Permitted Senior Debt Hedging Instruments—General 

  

	 	(i)	Each Senior Creditor Group party to a Senior Debt Instrument shall have the right to declare an Event of Default under its respective Senior Debt Instrument, and at any time thereafter: 

 

	 	(A)	give any draw-stop notice in accordance with its Senior Debt Instrument; 

  

	 	(B)	suspend, cancel or reduce its undrawn Senior Debt Commitments; 

  

	 	(C)	accelerate the outstanding Senior Debt Obligations under its Senior Debt Instrument; or 

  
 -78- 

 § 6.1(a)(i)(D) 

 

	 	(D)	take such other actions as are permitted under its Senior Debt Instrument, 

 in each case as,
when and on the terms and conditions provided in its Senior Debt Instrument and the Intercreditor Agreement (if applicable), as the case may be. If any of the foregoing actions are taken by any Senior Creditor Group, the related Senior Creditor
Group Representative shall promptly notify the Security Trustee (who in turn shall promptly notify each other Senior Creditor Group Representative) of any such action. 
  

	 	(ii)	Each Senior Creditor Group party to a Permitted Senior Debt Hedging Instrument shall have the right to declare an event of default or termination event under its respective Permitted Senior Debt Hedging Instrument, and
at any time thereafter take such actions as are permitted under its Permitted Senior Debt Hedging Instrument, in each case as, when and on the terms and conditions provided in its Permitted Senior Debt Hedging Instrument and, if applicable, the
Intercreditor Agreement (including Section 5.1 (Undertakings of Hedging Banks) of the Intercreditor Agreement), subject in each case to Section 7.3 (Hedging Banks). If any such actions are taken by any such Senior Creditor
Group, the related Senior Creditor Group Representative shall promptly notify the Security Trustee (who in turn shall promptly notify each other Senior Creditor Group Representative) of any such action. 

 

	 	(b)	Control of Accounts 

 If the Security Trustee receives notice: 

 

	 	(i)	from the Intercreditor Agent or any other party to the Intercreditor Agreement that a Loan Facility Declared Default has occurred and is Continuing; 

 

	 	(ii)	from an Indenture Trustee that an Indenture Declared Default has occurred and is Continuing; or 

  

	 	(iii)	from any future acceding intercreditor agent or Senior Creditor Group Representative (excluding, for the avoidance of doubt, any Senior Creditor Group Representative which has appointed the Intercreditor Agent as
contemplated in Section 2.5(c) (Other Intercreditor Agents)) that an Event of Default identified in the relevant Senior Debt Instrument as a “Declared Event of Default” has occurred and is Continuing,

 then the Security Trustee shall take the actions with respect to control and investment of funds in the Accounts specified
in Section 4.6(b) (Control and Investment of Funds in Accounts). 

  
 -79- 

 § 6.2(a) 

 

	 	(c)	Security Enforcement Action 

 Security Enforcement Action shall be taken only: 

 

	 	(i)	as provided in Sections 6.2 (Initiation of Security Enforcement Action) and 6.3 (Conduct of Security Enforcement Action); and 

 

	 	(ii)	by the Security Trustee or by another party at the direction of the Security Trustee. 

Accordingly, no Secured Party shall take or purport to take any action to enforce the Security Interests other than as provided by, and
pursuant to, this Article 6 (Security Trustee Action). 
  

	 	(d)	Draws on Letter of Credit under CMI Security Agreement 

 The Security Trustee is hereby
authorized to draw on any letter of credit provided by CMI (UK) to CCL under the CMI Security Agreement in order to pay the amounts due and payable by CMI (UK) to CCL under the DES-Linked LNG SPA in respect of
which such letter of credit was delivered to CCL as follows: 
  

	 	(i)	at any time following delivery of a Notice of Security Enforcement Action by the Security Trustee pursuant to Section 6.2(f) (Initiation of Security Enforcement Action – Notice of Security Enforcement
Action); 

  

	 	(ii)	if the letter of credit fails to qualify as an “Acceptable Letter of Credit” under the CMI Security Agreement and CCL has not drawn on such letter of credit, within three Business Days of such letter of credit
failure to so qualify; and 

  

	 	(iii)	if CMI (UK) fails to make a payment by the due date of such payment to CCL under the terms of the DES-Linked LNG SPA and CCL has not drawn on any letter of credit on deposit in
the Deposit Account, within three Business Days of such failure to pay. 

  

	 	6.2	Initiation of Security Enforcement Action 

  

	 	(a)	When permitted under the terms of the relevant Senior Debt Instrument (and, with respect to the Facility Agreements, the Intercreditor Agreement), and subject to Section 7.3 (Hedging Banks), any Senior
Creditor Group Representative, or the Intercreditor Agent on behalf of any Senior Creditor Group Representative, who represents a Senior Creditor Group that previously has declared an Event of Default under its Senior Debt Instrument that is
Continuing (or any future intercreditor agent duly appointed pursuant to Section 2.5 (Other Intercreditor Agents)) may deliver to the Security Trustee a written request to initiate a Security Enforcement Action (a
“Security Enforcement Action Initiation Request”) and the Security Trustee shall deliver a copy thereof to the Intercreditor Agent, each other Senior Creditor Group Representative and the Company; provided, however,
that failure to deliver a copy thereof to the Company shall not invalidate any Security Enforcement Action. 

  
 -80- 

 § 6.2(b)(i) 

 

	 	(b)	Any such Security Enforcement Action Initiation Request shall: 

  

	 	(i)	be labelled “Security Enforcement Action Initiation Request” and shall reference that it is being given pursuant to and for purposes of this Section 6.2 (Initiation of Security Enforcement Action);

  

	 	(ii)	state the Senior Creditor Group(s) on whose behalf it is being given, and the amount of outstanding Senior Debt Commitments and/or Senior Debt Obligations of such Senior Creditor Group(s); 

 

	 	(iii)	state the Declared Event(s) of Default under and in accordance with the relevant Senior Debt Instrument(s), with specific reference to the relevant provision(s) of such instrument(s); 

 

	 	(iv)	state whether such Declared Event(s) of Default include(s) a Bankruptcy Default; 

  

	 	(v)	state the Security Enforcement Action permitted in the circumstances under the relevant Security Documents and/or the Direct Agreements that the Security Trustee is thereby instructed to take (subject to
Section 6.1(c) (Security Trustee Action Generally – Security Enforcement Action)) and can, optionally, provide instructions regarding the conduct of the Security Enforcement Action as described in Section 6.3(b)
(Conduct of Security Enforcement Action); and 

  

	 	(vi)	certify that such instruction has been duly authorized by the taking of all necessary action by the relevant Senior Creditors on whose behalf such instruction is being delivered and is duly given, in each case in
compliance with the relevant Senior Debt Instrument (and, as applicable, the Intercreditor Agreement). 

  

	 	(c)	Bankruptcy Default 

 If any one or more of the Security Enforcement Action
Initiation Requests received by the Security Trustee pursuant to and in compliance with clause (b) above states that the Declared Event(s) of Default under the relevant Senior Debt Instrument(s) have included a Loan Facility Event of Default
under Section 15.1(d)(i) (Loan Facility Events of Default – Bankruptcy) of the Common Terms Agreement (a “Bankruptcy Default”) or its equivalent under any other Senior Debt Instrument, then such Security Enforcement
Action Initiation Request(s) shall be sufficient (regardless of whether or not the Senior Creditor Group Representatives giving such directions represent an Initiating Percentage of the Senior Debt Obligations) to require the Security Trustee to
take the directed Security Enforcement Action. 

  
 -81- 

 § 6.2(d) 

 

	 	(d)	Other Declared Event(s) of Default – Initiating Percentage 

 Except as set forth in
clause (c) (Bankruptcy Default) above, the Security Trustee shall only be authorized to initiate the requested Security Enforcement Action if and when it shall have received Security Enforcement Action Initiation Requests pursuant to and
in compliance with clause (b) above from Senior Creditor Group Representative(s) representing at such time an Initiating Percentage of the Senior Debt Obligations. 
  

	 	(e)	Votes Relating to Accounts Secured in Favor of any Individual Groups of Senior Noteholders 

Notwithstanding anything to the contrary in this Agreement, with regard to any group of Senior Noteholders who benefits from a Security
Interest in an Individual Senior Noteholder Secured Account that secures solely the Senior Debt Obligations under the Senior Debt Instrument to which such Senior Noteholders are a party (as provided in Section 3.2(c) (Security Interests to
be Granted by the Securing Parties – Security Interests – Individual Senior Noteholder Secured Accounts)), for the purposes of (i) calculating whether Security Enforcement Action Initiation Requests sufficient to take the directed
Security Enforcement Action in respect of Collateral that is secured in favor of all Secured Parties under this Agreement or any other Finance Document have been received by the Security Trustee and (ii) calculating any votes relating to the
conduct of such Security Enforcement Action, such Senior Noteholders shall not be entitled to vote their respective Senior Debt Obligations to the extent of any amounts standing to the account of such Senior Noteholder Secured Account at the time of
such vote and such Senior Debt Obligations that are not entitled to be voted shall be disregarded for purposes of the applicable vote. 
  

	 	(f)	Notice of Security Enforcement Action 

 Promptly following receipt of Security
Enforcement Action Initiation Requests sufficient to take the directed Security Enforcement Action pursuant to clause (c) (Bankruptcy Default) or clause (d) (Other Declared Event(s) of Default – Initiating Percentage)
above, the Security Trustee shall deliver a notice (a “Notice of Security Enforcement Action”) to each Senior Creditor Group Representative and the Intercreditor Agent and shall take the directed Security Enforcement Action, subject
to Section 6.3 (Conduct of Security Enforcement Action) and the other provisions of this Agreement. The Security Trustee shall, simultaneously with delivery of such notice to the Senior Creditor Group Representatives and Intercreditor
Agent or promptly thereafter, deliver a copy of such Notice of Security Enforcement Action to the Company; provided, however, that failure to deliver a copy thereof to the Company shall not invalidate any Security Enforcement Action.

  
 -82- 

 § 6.3(a) 

 

	 	6.3	Conduct of Security Enforcement Action 

  

	 	(a)	Following the receipt by the Security Trustee of Security Enforcement Action Initiation Requests sufficient to take Security Enforcement Action in accordance with Section 6.2 (Initiation of Security Enforcement
Action) until such time as the Security Trustee receives a Cessation Notice with respect to the relevant Declared Event(s) of Default that resulted in such Security Enforcement Action, any group of Senior Noteholders who benefits from a Security
Interest in an Individual Senior Noteholder Secured Account that secures solely the Senior Debt Obligations under the Senior Debt Instrument to which such Senior Noteholders are a party (as provided in Section 3.2(c) (Security Interests to
be Granted by the Securing Parties – Security Interests – Individual Senior Noteholder Secured Accounts)) may, subject to the terms of the applicable Senior Notes, at any time and at their sole discretion, direct the Security
Trustee to take any action to enforce such Security Interests of such Senior Noteholders in the funds and investments in such Individual Senior Noteholder Secured Account. 

 

	 	(b)	Subject to initiation of a Security Enforcement Action having been duly authorized pursuant to Section 6.2 (Initiation of Security Enforcement Action) and clause (h) below, the Security Enforcement
Action Representative shall be entitled to provide subsequent instructions regarding the conduct of the specified Security Enforcement Action that has previously been initiated pursuant to Section 6.2 (Initiation of Security Enforcement
Action). Such instructions may: 

  

	 	(i)	require the Security Trustee to enforce this Agreement and any other Finance Documents, either by judicial proceedings for the enforcement of the payment of Senior Debt Obligations and the enforcement of the Security
Interests created under the Security Documents, the sale of the Collateral or any part thereof or otherwise or by the exercise of the power of entry and/or sale conferred pursuant to the Security Documents and the Direct Agreements; and

  

	 	(ii)	direct the time, method and place of conducting any proceeding for any remedy available to the Security Trustee or exercising any trust or power conferred upon the Security Trustee hereunder or under any Security
Document or Direct Agreement; provided that: 

  

	 	(A)	such direction shall not be in conflict with applicable law nor this Agreement; and 

  

	 	(B)	the Security Trustee may take any other action reasonably incidental to carrying out any instruction to take any Security Enforcement Action. 

For the avoidance of doubt, upon delivery of a Notice of Security Enforcement Action, the Security Trustee shall conduct such Security
Enforcement Action in accordance with the instructions received as contemplated in Section 6.2(b)(v) 

  
 -83- 

 § 6.3(c) 

 

 
(Initiation of Security Enforcement Action) and shall not be required to wait for any subsequent instructions that may be provided in accordance with this Section 6.3 (Conduct of
Security Enforcement Action), but in the event instructions under this Section 6.3 (Conduct of Security Enforcement Action) are received, then such instructions shall, to the extent so provided by such instructions, govern the
implementation of the Security Enforcement Action to the extent not already addressed in the Security Enforcement Action Initiation Request. 
  

	 	(c)	Without limiting the generality of the foregoing, a Security Enforcement Action by the Security Trustee may include (but only if so instructed by the Initiating Percentage in a Security Enforcement Action Initiation
Request pursuant to Section 6.2(b)(v) (Initiation of Security Enforcement Action) above or the Security Enforcement Action Representative following initiation of a Security Enforcement Action pursuant to Section 6.2 (Initiation of Security
Enforcement Action)) the right, subject to applicable law, to take any other action as the holder of a security interest may be entitled to take under the laws in effect in any jurisdiction where any rights or remedies hereunder may be asserted,
including: 

  

	 	(i)	requiring any Collateral Party to assemble all or part of the Collateral as directed by the Security Trustee and make it available to the Security Trustee at a place to be designated by the Security Trustee that is
reasonably convenient to the Security Trustee and applicable Collateral Party; 

  

	 	(ii)	without notice except as specified in Section 6.4(a) (Incidents of Sale) or under the UCC, sell, assign, lease, license (on an exclusive or non-exclusive basis) or
otherwise dispose of the Collateral or any part thereof in one or more parcels at public or private sale, at any of the Security Trustee’s offices or elsewhere, for cash, on credit or for future delivery, at such time or times and at such price
or prices and upon such other terms as the Security Trustee may deem commercially reasonable; and 

  

	 	(iii)	exercising any other right or remedy of a secured creditor under applicable law, including, without limitation, the UCC, and all other rights under any Security Document or Direct Agreement. 

 

	 	(d)	Other than pursuant to Security Enforcement Action properly taken in accordance with this Agreement, no Secured Party shall have the right in respect of the Senior Debt Obligations owed to it or otherwise under this
Agreement to commence any Bankruptcy, judicial or otherwise, against any Collateral Party or its Affiliates. 

  

	 	(e)	 Other than pursuant to Security Enforcement Action properly taken in accordance with this Agreement or to the
extent required to be permitted under non-waivable Government Rules, no Secured Party shall have the right to commence any proceeding, judicial or otherwise, to enforce any judgment obtained by it in respect
of the Senior Debt Obligations or otherwise under the Finance Documents 

  
 -84- 

 § 6.3(e) 

 

	 	
against any Collateral Party or its Affiliates or their assets or properties or to enforce any provision of this Agreement, any other Finance Document or the Security Interests created under or
pursuant to any such document, it being understood and intended that no Secured Party shall have any rights in any manner whatsoever to affect, disturb or prejudice the Security Interests created under the Security Documents or the rights of any of
the other Secured Parties, or to obtain or seek to obtain priority or preference over any other Secured Party or to enforce any rights under this Agreement or any other Finance Document except in the manner herein provided. 

 

	 	(f)	Subject to Section 10.5 (Certain Agreements with Respect to Bankruptcy), following commencement of any Bankruptcy Proceeding by or against a Collateral Party, any Senior Creditor may: (i) file a claim
or statement of interest with respect to (and to the extent of) the Senior Debt Obligations (if any) owed by such person to such Senior Creditor in accordance with the Finance Documents, (ii) vote on any plan of reorganization and
(iii) make other filings, arguments, objections and motions in connection with such Bankruptcy Proceeding, in each case in accordance with the terms of the Finance Documents (other than any requirement for an intercreditor vote to take such
action). 

  

	 	(g)	Nothing in this Section 6.3 (Conduct of Security Enforcement Action) shall prevent the Secured Parties through the Security Trustee from taking action with respect to the Collateral reasonably designed to
preserve and protect their rights in, or to prevent any diminution in the value, utility or condition of, such Collateral so long as, prior to any Security Enforcement Action being taken, such action does not materially adversely affect any
Collateral Party or its respective Affiliates’ “quiet enjoyment” or use of the Collateral. 

  

	 	(h)	Notwithstanding any provision of this Section 6.3 (Conduct of Security Enforcement Action) to the contrary (including any requirement to give notice or otherwise), at any time that the Security Trustee
receives a notice from any counterparty under a Direct Agreement stating that a Securing Party is in default under a Material Project Agreement, the Security Trustee shall notify the Company of the receipt of such notice. The Security Trustee may
take any action to cure such default if directed by the Security Enforcement Action Representative. 

  

	 	(i)	The Security Trustee, on behalf of the Secured Parties, acknowledges and agrees that its right and remedies with respect to certain of the Collateral, including certain Permits and the Pledged Collateral, may be subject
to the requirements of the statutory rules and regulations applicable to the Permits held by the Securing Parties. The Security Trustee and Secured Parties further recognize and acknowledge that (i) the disposition of any such Collateral,
(ii) any direct or indirect change of control of a Securing Party and (iii) any direct or indirect exercise of management control or other control over a Securing Party may be subject to regulatory restrictions (including the need to
obtain consent or approval of the applicable regulatory authorities that have granted Permits to such Securing Party). 

  
 -85- 

 § 6.4(a) 

 

	 	6.4	Incidents of Sale 

  

	 	(a)	In addition to exercising the foregoing rights and subject to the terms of the Intercreditor Agreement, upon the initiation of a Security Enforcement Action, the Security Trustee may, to the extent permitted by
applicable Government Rules and in a commercially reasonable manner, time and place, arrange for and sell, lease, assign, pledge or otherwise dispose of all or any part of the Collateral for cash or for credit or for future delivery (without thereby
assuming any credit risk), at a public or private sale (as the Security Trustee may elect), which sale may be conducted by an employee or representative of the Security Trustee. The Security Trustee or any other Secured Party may be the purchaser of
any or all of the Collateral at any public or private sale in accordance with the UCC. Each purchaser at any such sale shall hold the property sold absolutely free from any claim or right on the part of the Collateral Parties, and each Collateral
Party hereby waives (to the extent permitted by applicable law) all rights of redemption, stay and/or appraisal which it now has or may at any time in the future have under any rule of law or statute now existing or hereafter enacted. The Collateral
Parties agree that, to the extent notice of sale shall be required by law, at least 10 days’ notice to such Collateral Party of the time and place of any public sale or the time after which any private sale is to be made shall constitute
reasonable notification. The Security Trustee shall not be obligated to make any sale of Collateral regardless of notice of sale having been given. The Security Trustee may adjourn any public or private sale from time to time by announcement at the
time and place fixed therefor, and such sale may, without further notice, be made at the time and place to which it was so adjourned. Each Collateral Party agrees that it would not be commercially unreasonable for the Security Trustee to dispose of
the Collateral or any portion thereof by using internet sites that provide for the auction of assets of the types included in the Collateral or that have the reasonable capability of doing so, or that match buyers and sellers of assets.

  

	 	(b)	Upon any sale of any of the Collateral by the Security Trustee for the benefit of the Secured Parties, whether made under the power of sale hereby given or pursuant to judicial proceedings, to the extent permitted by
applicable law, the Security Trustee may make and deliver, or cause to be made and delivered, to the purchaser or purchasers a good and sufficient deed, bill of sale and instrument of assignment and transfer of the property sold and may substitute
one or more Persons with like power (and the Securing Parties hereby ratify and confirm, and shall procure that Holdco ratify and confirm, all that their said attorney or such substitute or substitutes shall lawfully do by virtue of this Agreement;
but if so required by the Security Trustee or by any purchaser, the Securing Parties shall ratify and confirm, and procure that Holdco ratify and confirm, any such sale or transfer by executing and delivering to the Security Trustee or to such
purchaser or purchasers all proper deeds, bills of sale, instruments of assignment and transfer and releases as may be designated in any such request). 

  
 -86- 

 § 6.4(c) 

 

	 	(c)	The Securing Parties hereby waive and release to the fullest extent permitted by law all rights, if any, of marshalling the Collateral and any other security for the Senior Debt Obligations or otherwise.

  

	 	(d)	For purposes of bidding and making settlement or payment of the purchase price for all or a portion of the Collateral sold at any such sale made in accordance with the UCC or other applicable laws, including the
Bankruptcy Code, the Security Trustee, as agent for and representative of the Secured Parties (but not any Secured Party or Secured Parties in its or their respective individual capacities unless the Security Trustee shall otherwise agree in
writing), shall be entitled to credit bid and use and apply the Senior Debt Obligations (or any portion thereof) as a credit on account of the purchase price for any Collateral payable by the Security Trustee at such sale, such amount to be
apportioned ratably to the Senior Debt Obligations of the Secured Parties in accordance with their pro rata share of such Senior Debt Obligations; provided that any such arrangement shall not be undertaken in a manner that is
inconsistent with this Agreement. 

  

	 	(e)	The Security Trustee may release, temporarily or otherwise, to a Securing Party any item of Collateral of which the Security Trustee has taken possession pursuant to any right granted to the Security Trustee by this
Agreement without waiving any rights granted to the Security Trustee under this Agreement, any other Finance Document or any other agreement related thereto. Each Securing Party, in dealing with or disposing of the Collateral or any part thereof,
hereby waives all rights, legal and equitable, it may now or hereafter have to require marshaling of assets or to require, upon foreclosure, sales of assets in a particular order. The Security Trustee may sell the Collateral without giving any
warranties as to the Collateral. The Security Trustee may specifically disclaim or modify any warranties of title or the like. The foregoing shall not be considered to adversely affect the commercial reasonableness of any sale of the Collateral.
Each Securing Party also waives its right to challenge the reasonableness of any disclaimer of warranties, title and the like made by the Security Trustee in connection with a sale of the Collateral. If the Security Trustee sells any of the
Collateral upon credit, such Securing Party will be credited only with payments actually made by the purchaser, received by the Security Trustee and applied to the payment of the outstanding Senior Debt Obligations. In the event the purchaser fails
to pay for the Collateral, the Security Trustee may resell the Collateral, and such Securing Party shall be credited with the proceeds of the sale. In the event the Security Trustee shall bid at any foreclosure or trustee’s sale or at any
private sale permitted by applicable Government Rules, this Agreement or any other Finance Document, the Security Trustee may bid any amount, including more or less than the amount of the Senior Debt Obligations. To the extent permitted by
applicable Government Rules, the amount of the successful bid at any such sale, whether the Security Trustee or any other party is the successful bidder, shall, absent fraud or gross negligence, be conclusively deemed to be the fair market value of
the Collateral and the difference between such bid amount, if less than the amount of the Senior Debt Obligations, and the remaining balance of the Senior Debt Obligations shall be conclusively deemed to be the amount of the Senior Debt Obligations.

  
 -87- 

 § 6.4(e) 

 

	 	(f)	Each Securing Party recognizes that, by reason of certain prohibitions contained in the Securities Act of 1933, as amended, applicable state securities laws or other applicable Government Rules, the Security Trustee or
an investment banker or other expert employed by the Security Trustee may be compelled, with respect to any sale of all or any part of the Collateral, to limit purchasers to those who will agree, among other things, to acquire the Collateral for
their own account, for investment and not with a view to the distribution or resale thereof. Each Securing Party acknowledges that any such private sales may be at prices and on terms less favorable to the Security Trustee than those obtainable
through a public sale without such restrictions, and, notwithstanding such circumstances, agrees that the inclusion of such restriction shall not deem such private sale to have not been made in a commercially reasonable manner and that the Security
Trustee or an investment banker or other expert employed by the Security Trustee shall have no obligation to engage in public sales and no obligation to delay the sale of any Collateral for the period of time necessary to permit the respective
issuer thereof to register it for public sale. Subject to compliance by the Security Trustee with this Agreement, the Securing Parties hereby waive any claims against the Security Trustee arising by reason of the fact that the price at which any
Collateral may have been sold at a private sale was less than the price which might have been obtained at a public sale, even if the Security Trustee accepts the first offer received and does not offer such Collateral to more than one offeree.

  

	 	(g)	In respect of any sale of any of the Collateral pursuant to the terms hereof, the Security Trustee is hereby authorized to comply with any limitation or restriction in connection with such sale as it may be advised by
counsel is necessary in order to avoid any violation of applicable Government Rules, or in order to obtain any required approval of the sale or of the purchaser by any Governmental Authority or official, and such compliance shall not result in such
sale being considered or deemed not to have been made in a commercially reasonable manner, nor shall the Security Trustee be liable or accountable to any Securing Party for any discount allowed by reason of the fact that such Collateral is sold in
compliance with any such limitation or restriction. 

  

	 	(h)	In exercising its right to take possession of the Collateral following the initiation of a Security Enforcement Action hereunder, the Security Trustee, personally or by its agents or attorneys, to the fullest extent
permitted by applicable Government Rules, may enter upon any land owned or leased by each of the Securing Parties without being guilty of trespass or any wrongdoing, and without liability to any Securing Party for damages thereby occasioned.

  

	 	(i)	 If, in the exercise of any of its rights and remedies under this Agreement, the Security Trustee shall forfeit
any of its rights or remedies, whether because of any applicable Government Rules pertaining to “election of remedies” or otherwise, each Securing Party hereby consents to such action by the Security Trustee and, to

  
 -88- 

 § 6.4(i) 

 

	 	
the extent permitted by applicable Government Rules, waives any claim based upon such action, even if such action by the Security Trustee shall result in a full or partial loss of any rights of
subrogation, indemnification or reimbursement which any Securing Party might otherwise have had but for such action by the Security Trustee or the terms herein. Any election of remedies which results in the denial or impairment of the right of the
Security Trustee to seek a deficiency judgment against any Securing Party shall not, to the extent permitted by applicable Government Rules, impair any Securing Party’s obligation hereunder. 

 

	 	6.5	Security Trustee May File Proofs of Claim 

 During the pendency of any Bankruptcy
Proceeding in relation to a Collateral Party or the Collateral, the Security Trustee, irrespective of whether the principal of the Senior Debt Obligations shall then be due and payable, shall be entitled and empowered, by intervention in such
proceeding or otherwise: 
  

	 	(a)	to file and prove a claim for the whole amount of the Senior Debt Obligations owing to the Secured Parties and unpaid and to file such other papers or documents as may be necessary or advisable in order to have the
claims of the Security Trustee (including any claim for the reasonable compensation, disbursements and advances of the Security Trustee, as such hereunder, its agents and counsel) and of the Secured Parties allowed in such judicial proceeding; and

  

	 	(b)	to collect and receive any monies or other property payable or deliverable on any such claims and to distribute the same; and any custodian, Receiver, assignee, security trustee, liquidator, sequestrator or other
similar official in any such judicial proceeding is hereby authorized by each Secured Party to make such payments to the Security Trustee. 

  

	 	6.6	Security Trustee May Enforce Claims 

 All rights of action and claims under this
Agreement may be prosecuted and enforced by the Security Trustee in its own name as Security Trustee of an express trust; provided, however, that the Security Trustee is also hereby appointed as agent for the Secured Parties for this
and the other purposes of this Agreement, and the Security Trustee may, if necessary under applicable law, pursue any such rights of action and/or claims solely as agent for the Secured Parties and/or delegate the performance of such action to a
third Person. Any recovery of judgment by the Security Trustee shall be for the benefit of the Secured Parties and deposited in the Enforcement Proceeds Account for application as provided in Section 6.7 (Enforcement Proceeds Account).

  

	 	6.7	Enforcement Proceeds Account 

  

	 	(a)	 Upon the authorization to commence Security Enforcement Action pursuant to Section 6.2 (Initiation of
Security Enforcement Action), the Security Trustee shall establish and thereafter maintain in its name a segregated bank account in the United States (the “Enforcement Proceeds Account”) for the purpose of depositing therein the
proceeds of any Security Enforcement Action (net of costs 

  
 -89- 

 § 6.7(a) 

 

	 	
and expenses of such action) taken pursuant to this Article 6 (Security Trustee Action) and all proceeds otherwise received for satisfaction of the Senior Debt Obligations. The
Securing Parties acknowledge and agree that the Enforcement Proceeds Account shall be the property of the Security Trustee (for the benefit of the Secured Parties) and the Securing Parties shall not have any legal or beneficial interest therein at
any time. 

  

	 	(b)	All monies held in the Enforcement Proceeds Account shall be trust funds held by the Security Trustee for the benefit of the Secured Parties for the purpose of making payments in the following order of priority:

  

	 	(i)	first, to payment of that portion of the Secured Party Fees then due and payable to the Security Trustee, the Account Bank or the Intercreditor Agent, in their respective capacities as such or any of their
respective agents and to reimbursement of any such fees paid by way of indemnity by any Senior Creditor; 

  

	 	(ii)	second, to the payment of that portion of the Secured Party Fees then due and payable to the Senior Creditor Group Representatives and to reimbursement of any such fees paid by way of indemnity by any Senior
Creditor, in each case ratably in proportion to the respective Secured Party Fees due and payable to each Senior Creditor Group Representative; 

  

	 	(iii)	third, to the Pro Rata Payment among the holders thereof, of that portion of the Senior Debt Obligations constituting unpaid interest (including default interest and any net amounts under any Permitted Hedging
Instrument in respect of interest rates); 

  

	 	(iv)	fourth, to the Pro Rata Payment among the holders thereof, of that portion of the Senior Debt Obligations constituting unpaid principal and Hedging Termination Amounts; 

 

	 	(v)	fifth, to cash collateralize any outstanding letters of credit comprising Senior Debt Obligations; 

  

	 	(vi)	sixth, to the Pro Rata Payment among the holders thereof, of other Senior Debt Obligations; and 

  

	 	(vii)	seventh, after the payment in full of the amounts in sub-clauses (i) through (vi) above, the payment of the remainder, if any, to the Securing Parties or the Securing
Parties’ successors (or to Holdco or its applicable Affiliate, as the case may be), or as a court of competent jurisdiction in the State of New York may otherwise direct. 

 

	 	(c)	 In applying any monies towards satisfaction of the Senior Debt Obligations, the Securing Parties shall be
credited only with funds available for that purpose that actually are received by the Security Trustee. The credit shall date from the time of receipt of such funds by the Security Trustee. Such funds shall be apportioned

  
 -90- 

 § 6.7(c) 

 

	 	
by the Security Trustee as between principal, interest and other amounts in accordance with the order set forth in Section 2.3(d) (Payments and Prepayments – Partial
Payments). Any such apportionment by the Security Trustee shall override any apportionment made by a Securing Party. 

  

	 	6.8	Rights of Enforcement under the Security Documents 

 Notwithstanding anything in this
Agreement, no Security Document or Direct Agreement shall include rights of enforcement that are inconsistent with those provided in this Article 6 (Security Trustee Action) or have the effect of deviating from or changing the rights and
obligations of the Parties set forth in this Agreement and in the other Finance Documents. 
  

	 	6.9	Rights of Set-Off 

 If a Security Enforcement
Action has been previously initiated, each of the Senior Creditors and (subject to Section 8.21(e) (Miscellaneous)) the Security Trustee is hereby authorized at any time and from time to time, to the fullest extent permitted by law but
subject to any other provision of this Agreement and the other Finance Documents, to set off and apply any and all deposits (general or special, time or demand, provisional or final) at any time held and other indebtedness at any time owing by such
Senior Creditor or the Security Trustee, as applicable, to or for the credit or the account of the Securing Parties against the Senior Debt Obligations due and payable to such Senior Creditor or the Security Trustee, as applicable, at the time of
such set-off. If the obligations are in different currencies, the Senior Creditor or the Security Trustee, as applicable, may convert either obligation at a market rate of exchange in its usual course of
business for the purposes of the set-off. The rights of each Senior Creditor and (subject to Section 8.21(e) (Miscellaneous)) the Security Trustee under this Section 6.9 (Rights of Set-Off) are in addition to other rights and remedies (including other rights of set-off) that such Senior Creditor or the Security Trustee, as applicable, may have. Upon
the exercise or purported exercise of any right of set-off by a Senior Creditor, such Senior Creditor shall notify its respective Senior Creditor Group Representative and the Securing Parties forthwith, giving
full details in relation thereto, and such Senior Creditor Group Representative shall promptly inform the Security Trustee who shall inform the other Senior Creditor Group Representatives of the same. Upon the exercise or purported exercise of any
right of set-off by the Security Trustee, it shall notify each Senior Creditor Group Representative and the Securing Parties forthwith, giving full details in relation thereto. For the avoidance of doubt, any
amounts obtained by set-off by any Senior Creditor in accordance with the foregoing shall be subject to sharing as provided in Section 2.3(b) (Payments and Prepayments – Sharing of Non-Pro Rata Payments). 

  
 -91- 

 § 7.1 
  

	7.	INTERCREDITOR ARRANGEMENTS 

  

	 	7.1	Other Intercreditor Arrangements 

  

	 	(a)	Each of the Security Trustee and the Senior Creditor Group Representatives acknowledges that: 

  

	 	(i)	the Senior Creditor Group Representative(s) representing any Facility Lender or representing itself as a Hedging Bank, if any, and the Intercreditor Agent are entering into the Intercreditor Agreement, pursuant to which
such Senior Creditor Group Representative(s) may consult, meet, vote, act and instruct the Intercreditor Agent as provided therein; 

  

	 	(ii)	the Senior Noteholders (if any) subject to a specific Indenture are bound by the terms of such Indenture and subject to the terms of such Indenture, and all Senior Noteholders subject to such specific Indenture shall
vote as one Senior Creditor Group under such Indenture and be represented by the Indenture Trustee under such Indenture acting as the Senior Creditor Group Representative; and 

 

	 	(iii)	individual Senior Debt Instruments may also provide for the Senior Creditors thereunder (including parties thereto in the capacity of guarantors or obligors under credit insurance policies) to vote or act in respect of
specified matters thereunder. 

  

	 	(b)	Each of the Security Trustee and the Senior Creditor Group Representatives agrees that: 

  

	 	(i)	each intercreditor agreement or arrangement is for the sole and exclusive benefit of the Senior Creditors (or represented by any Senior Creditor Group Representative) party thereto, and no other Senior Creditors shall
have rights thereunder or be entitled to rely thereon; 

  

	 	(ii)	subject to the provisions of Section 2.4 (Initial Senior Creditor Group Representative; Replacement or Appointment of Senior Creditor Group Representative) and Section 2.5 (Other
Intercreditor Agents), the Security Trustee and each other Senior Creditor Group Representative shall be entitled to conclusively rely upon and have no duty to investigate whether any notice, instruction, direction or action given
by a Senior Creditor Group Representative, the Intercreditor Agent, or any other intercreditor agent has been duly authorized or properly given in compliance with such intercreditor agreements or arrangements; and 

 

	 	(iii)	if the need for a decision requiring a vote under the Intercreditor Agreement comes to their attention, they will promptly notify the Intercreditor Agent. 

  
 -92- 

 § 7.2(a)(i) 

 

	 	7.2	Modification Approval Levels 

  

	 	(a)	Modifications to this Agreement  

  

	 	(i)	Except as set forth in sub-clause (ii) below, Modifications to this Agreement may be made by the Security Trustee with the prior consent of (A) as long as the Common
Terms Agreement is in effect, the Intercreditor Agent based on approval received pursuant to the terms of the Intercreditor Agreement and (B) otherwise, a Majority in Interest of the Senior Creditors. 

 

	 	(ii)	The following Modifications to this Agreement may not be made without the consent of each Senior Creditor Group Representative (subject to Section 7.3 (Hedging Banks)) that is then party to this Agreement:

  

	 	(A)	Modifying the ranking of Senior Debt Obligations; 

  

	 	(B)	Modifying any pro rata payment or repayment requirements (not including waiver of the right to receive a pro rata payment or repayment) in Section 2.3 (Payments and Prepayments);

  

	 	(C)	Modifying the order of payments in the cash waterfall in Section 4.7 (Cash Waterfall), Section 4.8 (Accounts During the Continuance of a Declared Event of Default) or the order of
payments in Section 6.7(b) (Enforcement Proceeds Account); 

  

	 	(D)	Modifying the list of lender actions set out in this sub-clause (ii) in any way adverse to any Senior Creditor Group or Modifying any other term of this Agreement that
expressly requires the consent or agreement of all Senior Creditor Group Representatives; 

  

	 	(E)	Modifying the definition of “Majority in Interest of the Senior Creditors”, “Initiating Percentage” or “Security Enforcement Action Representative” as used in this Agreement; and

  

	 	(F)	Modifying any other thresholds for voting among Senior Creditor Groups in this Agreement in any way adverse to any Senior Creditor Group. 

 

	 	(b)	Modifications to Other Finance Documents 

  

	 	(i)	Subject to the terms of the Intercreditor Agreement with respect to Loans and Permitted Senior Debt Hedging Instruments and to the terms in sub-clause (ii) below, each Senior
Creditor Group may agree to a Modification under or to its own Senior Debt Instruments in accordance with the terms of such Senior Debt Instruments. 

  
 -93- 

 § 7.2(b)(ii)(A) 

 

	 	(ii)	Each of the Security Trustee and each Senior Creditor Group Representative hereby agrees that it shall not (and no member of the Senior Creditor Group represented by such Senior Creditor Group Representative shall)
agree to any Modification of any Finance Document to which such Person is a party, that has any of the following effects, without the prior consent of all Senior Creditor Group Representatives: 

 

	 	(A)	any shortening of the stated maturity of the Senior Debt outstanding under any Senior Debt Instrument or Permitted Senior Debt Hedging Instrument; provided that acceptance of any prepayment required or permitted
by any such Senior Debt Instrument or Permitted Senior Debt Hedging Instrument shall not be considered a Modification for this purpose; provided, further, that the agreement of any Indenture Trustee with respect to shortening the
stated maturity of the Loans (including through any refinancing thereof) shall not be required where such change will not result in an Indenture Projected Fixed DSCR calculated pursuant to the Indenture on a pro forma basis taking into
account such change of less than 1.55:1.00 or, if lower, an Indenture Projected Fixed DSCR of less than the Indenture Projected Fixed DSCR calculated pursuant to the Indenture on a pro forma basis made for such purpose within 30 days prior to
such change; 

  

	 	(B)	any increase in the stated rate of interest payable on the Senior Debt Obligations outstanding under any Senior Debt Instrument or Permitted Senior Debt Hedging Instrument; provided, that the agreement of any
Indenture Trustee with respect to an immaterial increase in such rate of interest for the then-outstanding Loans shall not be required where such change will not result in an Indenture Projected Fixed DSCR calculated pursuant to the Indenture on a
pro forma basis taking into account such change of less than 1.55:1.00 or, if lower, an Indenture Projected Fixed DSCR of less than the Indenture Projected Fixed DSCR calculated pursuant to the Indenture on a pro forma basis made for
such purpose within 30 days prior to such change; 

  

	 	(C)	any shortening of the time for payment of interest due on any Senior Debt; provided that acceptance of any prepayment required or permitted by any such Senior Debt Instrument or Permitted Senior Debt Hedging
Instrument shall not be considered a Modification for this purpose; provided, further, that the agreement of any Indenture Trustee with respect to a change in the time for payment of interest shall not be required where such change
will not result in an Indenture Projected Fixed DSCR calculated pursuant to the Indenture on a pro forma basis taking into account such change of less than 1.55:1.00 or, if lower, an Indenture Projected Fixed DSCR calculated pursuant to the
Indenture of less than the Indenture Projected Fixed DSCR on a pro forma basis made for such purpose within 30 days prior to such change; 

  
 -94- 

 § 7.2(c) 

 

	 	(D)	Modifying the currency of any Senior Debt; and 

  

	 	(E)	Modifying the list of lender actions set out in this sub-clause (ii) in any way adverse to any Senior Creditor Group. 

 

	 	(c)	Release of Collateral, Security Interests or Guarantees 

  

	 	(i)	Except as provided in Section 3.8 (Release or Modification of Security Interests), Article 11 (Guarantees) or pursuant to any other express provision hereof, the Security Trustee shall not release or
surrender all or any material portion of the Collateral, Security Interests or the guarantees by the Guarantors, or agree to the termination of any Security Document or Direct Agreement or the modification of any Security Document or Direct
Agreement that has the effect of releasing or surrendering all or any material portion of the Collateral, Security Interests or the guarantees by the Guarantors or modifying the priority of the Security Interests except upon receipt of a direction
to that effect from each Senior Creditor Group Representative representing those Senior Creditors that benefit from such relevant Collateral, Security Interest or guarantee. 

 

	 	(d)	Other Security Trustee Actions 

  

	 	(i)	The Security Trustee shall not agree to any Modification of any Finance Document to which it is a party or take any other action under any Finance Document except (A) as expressly permitted under this Agreement
(including Section 12.14 (Amendments) and this Section 7.2 (Modification Approval Levels)) or in any other Finance Document, or (B) to the extent that there is no relevant express provision in this Agreement or in any
other Finance Document, in accordance with the instructions of (x) for so long as the Common Terms Agreement is outstanding, the Intercreditor Agent and (y) at any other time, the Senior Creditor Group Representatives representing the
Majority in Interest of the Senior Creditors, which in each case shall be deemed to constitute the necessary Requisite Secured Party instruction. 

  

	 	(ii)	If a Declared Event of Default has occurred and is Continuing, and if so directed by (x) the Majority in Interest of the Senior Creditors and (y) for so long as the Common Terms Agreement is outstanding, the
Intercreditor Agent, the Security Trustee shall direct a Hedging Bank to terminate its Permitted Senior Debt Hedging Instruments provided that the Hedging Bank is otherwise permitted to do so as between it and the relevant Securing Party in
accordance with this Agreement, the Intercreditor Agreement, the Permitted Senior Debt Hedging Instrument and each relevant Senior Debt Instrument. 

  
 -95- 

 § 7.2(e) 

 

	 	(e)	Senior Creditor Actions 

  

	 	(i)	All action by the Senior Creditors (acting through their respective Senior Creditor Group Representatives) shall be taken on a “block voting” basis whereby each Senior Creditor Group Representative shall, with
respect to the matters on which it has the right to vote, act as a unanimous block in respect of all of the outstanding principal amount of the Senior Debt held by the Senior Creditors it represents (and, except with respect to the exercise of
remedies or where acceleration or deemed acceleration has occurred with respect to such Senior Debt, the aggregate principal amount of Senior Debt Commitments). 

  

	 	(ii)	For the avoidance of doubt, subject to the terms of any Indenture, all Senior Noteholders shall act as one Senior Creditor Group and shall be represented by the Indenture Trustee acting as the Senior Creditor Group
Representative; provided that Senior Noteholders who have the benefit of a Security Interest in an Individual Senior Noteholder Secured Account shall not be entitled to vote in relation to any Decision under this Agreement to the extent of
any amounts standing to the credit of that Individual Senior Noteholder Secured Account (other than in respect of any Decision under this Agreement or Security Enforcement Action relating to such Individual Senior Noteholder Secured Account).

  

	 	(f)	No Voting 

 For the avoidance of doubt, nothing in this Agreement requires Senior
Creditors to meet or vote in order to give any instructions or directions or for any other purpose. The Security Trustee is entitled to conclusively rely on written instructions and directions received from all Senior Creditor Group Representatives
or Senior Creditor Group Representative(s) (including the Intercreditor Agent) acting as Security Enforcement Action Representative or representing an Initiating Percentage of Senior Debt Obligations, a Majority in Interest of the Senior Creditors
or any other required percentage of Senior Debt Obligations, or the Intercreditor Agent, as applicable. 
  

	 	7.3	Hedging Banks 

  

	 	(a)	Subject to clause (c) below, notwithstanding anything to the contrary in this Agreement or any other Finance Document, any Senior Creditor Group Representative representing a Hedging Bank (in its capacity as Senior
Creditor Group Representative of such Hedging Bank) shall not be entitled to vote on or consent to decisions on any matter under this Agreement or any other Finance Document or to instruct the Security Trustee except: 

 

	 	(i)	with respect to Modifications of its respective Permitted Senior Debt Hedging Instruments; 

  
 -96- 

 § 7.3(a)(iii) 

 

	 	(ii)	with respect to Modifications of this Section 7.3 (Hedging Banks) and Section 3.7 (Voting by Hedging Banks) and Section 5 (Agreement of Hedging Banks) of the Intercreditor Agreement;
and 

  

	 	(iii)	with respect to a Modification to any Finance Document (other than its Permitted Senior Debt Hedging Instrument) in a manner that would impact the rights of such Hedging Bank in a manner materially and adversely
different from the impact on any other Secured Party. 

  

	 	(b)	Where permitted to vote, to consent or to instruct in accordance with clause (a) above or (c) below, the rights of any Senior Creditor Group Representative representing Hedging Banks shall be determined by
reference to the net positive Hedging Termination Amount due and unpaid from the relevant Securing Party to such Hedging Banks at such time as calculated pursuant to the Permitted Hedging Instruments. 

 

	 	(c)	Notwithstanding clause (a) above, following the date on which any Senior Debt Obligations are accelerated in accordance with the Finance Documents, no Modification shall be made to any Finance Document in a manner
that would impact the rights of a Hedging Bank in a manner materially and adversely different from the impact on any other Secured Party without the written consent of such Hedging Bank. 

 

	 	7.4	Sponsor Voting 

 The Sponsor and its Affiliates shall have no right to consent (or not
consent), otherwise act or direct or require the Intercreditor Agent or any Senior Creditor Group Representative to take (or refrain from taking) any such action, and all Senior Debt held by the Sponsor and its Affiliates shall be deemed to be not
outstanding for all purposes of calculating whether a required voting threshold has been met, except that no Modification of any Senior Debt Instrument shall, without the consent of Sponsor or the applicable Affiliate (to the extent they hold any
Senior Debt under such Senior Debt Instrument), (i) deprive Sponsor or the applicable Affiliate of its pro rata share of any payment to which all Senior Creditors of the applicable Senior Debt are entitled, (ii) affect Sponsor or the
applicable Affiliate (solely in their capacity as holders of such Senior Debt) in a manner that is disproportionate to the effect on any Senior Creditor of the applicable Senior Debt or (iii) change this Section 7.4 (Sponsor
Voting). 
  

	 	7.5	Notice and Consultation 

  

	 	(a)	Without prejudice to, or in any way limiting, the discretion, rights and prerogatives of the individual Senior Creditors and Senior Creditor Groups under their respective Senior Debt Instruments and Permitted Senior
Debt Hedging Instruments and hereunder (or, with respect to the Facility Lenders and any Hedging Banks, the requirements and operation of the Intercreditor Agreement), each Senior Creditor Group Representative shall notify the Security Trustee and
each other Senior Creditor Group Representative of: 

  
 -97- 

 § 7.5(a)(i) 

 

	 	(i)	any refusal or failure to fund a Senior Debt Commitment when requested by the Company; 

  

	 	(ii)	receipt of notice from any Collateral Party (that is not also addressed to the Security Trustee) of an event which is, or with the giving of notice or passage of time would become, an event of default under its Senior
Debt Instrument or Permitted Senior Debt Hedging Instrument; and 

  

	 	(iii)	receipt of a request from any Collateral Party (that is not also addressed to the Security Trustee) of a request for an amendment, consent, approval or waiver under a Senior Debt Instrument or Permitted Senior Debt
Hedging Instrument. 

  

	 	(b)	The Intercreditor Agent on behalf of the Facility Lenders and any Hedging Banks, any Indenture Trustee on behalf of Senior Noteholders, and any future acceding Senior Creditor Group Representative agree, upon the
reasonable request of any of them, to consult with respect to any of the foregoing; provided that none of them shall have any liability to the others or to the Loan Parties for any failure to so consult and none of them shall be obligated to
delay or withhold any declaration, consent, approval, waiver or other action pending such consultation. Without limiting the generality of the foregoing, such consultation may take the form of an invitation by the Intercreditor Agent to an Indenture
Trustee to participate in any meeting convened pursuant to the Intercreditor Agreement. 

  

	 	7.6	Intercreditor Agent Indemnity 

  

	 	(a)	The Securing Parties agree to indemnify (without duplication in respect of any other indemnity required under Section 12.18 (Other Indemnities) or any other Finance Document) the Intercreditor Agent in its
individual capacity and its directors, officers, agents and employees for, and to hold each of them harmless against, any loss, damage, liability, claim, judgment, settlement, compromise, obligation, damage, penalty, cost, expense or disbursement of
any kind or nature whatsoever (including reasonable attorneys’ fees and expenses) incurred by the Intercreditor Agent with respect to the execution, delivery, enforcement, performance and administration of this Agreement and the other Finance
Documents, unless arising from the gross negligence, fraud or willful misconduct of the Intercreditor Agent or the Persons that are seeking indemnification, as determined by a court of competent jurisdiction in a final
non-appealable judgment, including the costs and expenses of defending itself against any claim of liability in the premises. To the extent that the undertakings to defend, indemnify, pay and hold harmless set
forth in this Section 7.6 (Intercreditor Agent Indemnity) may be unenforceable in whole or in part because they are violative of any law or public policy, each Securing Party shall contribute the maximum portion that it is
permitted to pay and satisfy under applicable law to the payment and satisfaction of all indemnified liabilities incurred by the Intercreditor Agent and its directors, officers, agents and employees or any of them. 

  
 -98- 

 § 7.6(b) 

 

	 	(b)	Without limiting the liability of the Securing Parties under the Finance Documents, if the Securing Parties fail to comply with their obligations under clause (a) above, each Senior Creditor shall (based on the
proportion of indebtedness owed to it by the Company relative to the aggregate indebtedness owed by the Company to all Senior Creditors under the Senior Debt Instruments and the Permitted Senior Debt Hedging Instruments) indemnify the Intercreditor
Agent, within five Business Days of demand, against any loss, liability, claim, judgment, settlement, compromise, obligation, damage, penalty, cost, expense or disbursement of any kind or nature whatsoever (including reasonable attorneys’ fees
and expenses) incurred by the Intercreditor Agent with respect to the execution, delivery, enforcement, performance and administration of this Agreement and the other Finance Documents, unless arising from the Intercreditor Agent’s gross
negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in a final non-appealable judgment. 

 

	 	(c)	The Securing Parties shall, within five Business Days of demand (but without duplication of indemnification otherwise received by the Intercreditor Agent from the Securing Parties), reimburse each Senior Creditor for
any payment properly made by it under clause (b) above upon production of a certificate from each such Senior Creditor setting out details of such payment, and all such amounts shall comprise “Senior Debt Obligations.”

  

	 	(d)	If any indemnity furnished to the Intercreditor Agent for any purpose shall, in the reasonable opinion of the Intercreditor Agent, be insufficient or become impaired, the Intercreditor Agent may call for additional
indemnity and cease, or not commence, to do the acts indemnified against until such additional indemnity is furnished; provided that in no event shall this sentence require any Senior Creditor to indemnify the Intercreditor Agent against
liability, obligation, loss, damage, penalty, action, judgment, suit, cost, expense or disbursement in excess of such Senior Creditor’s pro rata share thereof; provided, further, that this sentence shall not be deemed to
require any Senior Creditor to indemnify the Intercreditor Agent against any liability, obligation, loss, damage, penalty, action, judgment, suit, cost, expense or disbursement arising from the Intercreditor Agent’s gross negligence, fraud or
willful misconduct, as determined by a court of competent jurisdiction in a final non-appealable judgment. 

  

	 	(e)	The agreements in this Section 7.6 (Intercreditor Agent Indemnity) shall survive the resignation or removal of the Intercreditor Agent and the termination of the other provisions of this Agreement.

  

	8.	THE SECURITY TRUSTEE 

  

	 	8.1	Appointment and Duties 

  

	 	(a)	 Each of the Secured Parties hereby irrevocably appoints Société Générale as the
Security Trustee hereunder, and the Security Trustee hereby accepts such appointment created in this Agreement upon the terms and conditions hereof and 

  
 -99- 

 § 8.1(a) 

 

	 	
agrees to act as Security Trustee under the Finance Documents, and each Senior Creditor Group Representative hereby acknowledges and consents to such appointment. The Secured Parties hereby
authorize and direct the Security Trustee to act as agent on their behalf and to execute, deliver and perform each Security Document and other Finance Document to which the Security Trustee is a party (including in which it is expressed to be a
party on behalf of or for the benefit of the Secured Parties), as the same may be amended, supplemented, revised or renewed from time to time. No party hereto may inquire into the authority of the Security Trustee to act for any of the Secured
Parties. Where the Security Trustee is required or permitted to act under this Agreement or under any other Finance Document, the Security Trustee shall, notwithstanding anything herein or therein to the contrary, (i) be entitled to request
instruction or direction in respect of any such rights, powers and discretions or clarification of any written instruction received by it, as to whether, and in what manner, it should exercise or refrain from exercising its rights, powers and
discretions and (ii) unless the terms of the agreement unambiguously mandate the action, may refrain from acting (and will incur no liability in refraining to act) until that direction, instruction or clarification is received by it from the
relevant parties or from a court of competent jurisdiction. 

  

	 	(b)	The Security Trustee shall have no duties other than those specifically set forth or provided for in this Agreement, the Security Documents and other Finance Documents and no implied covenants or obligations of the
Security Trustee shall be read into this Agreement, the Security Documents, other Finance Documents or any related agreement to which it is a party, except for an implied covenant of good faith. The Security Trustee may refrain from acting or
exercising any of its rights, powers and discretions hereunder or under any of the other Finance Documents unless and until instructed to do so, and as to the manner of doing so, by the relevant Secured Parties. 

 

	 	(c)	Except to the extent that a Security Trustee is acting on express instructions, the Security Trustee shall exercise such of the rights and powers vested in it by this Agreement, and use the same degree of care and skill
in their exercise as a prudent Person would exercise or use under the circumstances in the conduct of his or her own affairs (taking into account the interests of all the Secured Parties benefiting from this Agreement) and the Security Trustee shall
at all times take such care in dealing with the Collateral as the Security Trustee would in dealing with his or her own property. 

  

	 	(d)	The Security Trustee may not begin any legal action or proceeding in the name of a Senior Creditor, a Senior Creditor Group or Senior Creditor Group Representative except as specifically permitted under the terms of the
Finance Documents. 

  

	 	(e)	The Security Trustee shall not be liable to the Securing Parties for any breach by any Secured Party of any Finance Document or be liable to any Secured Party for any breach by any Collateral Party of the Finance
Documents. 

  
 -100- 

 § 8.1(f) 

 

	 	(f)	The Security Trustee shall not be bound to account to any Secured Party for any sum or profit element of any sum received by it for its own account. 

 

	 	(g)	The Security Trustee is not obliged to, and the Security Trustee shall not, monitor the performance by any Collateral Party or any Secured Party of their respective obligations hereunder or under any Finance Document,
nor is the Security Trustee obliged to investigate or inquire into the affairs (financial or otherwise) of any Collateral Party and/or any Secured Party, and no party should rely on the Security Trustee for any such investigations or inquiries.

  

	 	(h)	The provisions of this Article 8 (The Security Trustee) are solely for the benefit of the Security Trustee and the Secured Parties, and the Securing Parties shall have no rights as a third-party beneficiary of
any of the provisions thereof. Except as otherwise expressly provided herein, in performing its functions and duties hereunder, the Security Trustee shall act solely as an agent of the Secured Parties and does not assume and shall not be deemed to
have assumed any obligation towards or relationship of agency or trust with or for the Securing Parties. 

  

	 	8.2	Delivery of Documentation 

  

	 	(a)	Executed counterparts of this Agreement and the other Finance Documents (other than any Fee Letter to which it is not a party) have been, or promptly following execution thereof will be, delivered to the Security
Trustee and the Security Trustee acknowledges receipt thereof. 

  

	 	(b)	The Securing Parties and each Secured Party agree to deliver (and the Securing Party shall procure that any Collateral Party delivers, to the extent applicable) to the Security Trustee: 

 

	 	(i)	executed counterparts of any instrument amending or modifying any agreement to which it is a party that was previously delivered to the Security Trustee; and 

 

	 	(ii)	executed counterparts of any Accession Agreements, Senior Debt Instruments and Permitted Senior Debt Hedging Instruments entered into from time to time. 

 

	 	8.3	Attorney-in-Fact 

  

	 	(a)	 The Security Trustee or any officer or agent thereof, with full power of substitution and delegation, is hereby
irrevocably appointed as the true and lawful attorney-in-fact of the Collateral Parties and each Secured Party for the purpose of carrying out the provisions of this
Agreement and any of the other Finance Documents and taking any action and executing any instruments which the Security Trustee, at the direction of the Senior Creditor Group Representatives in accordance with the Finance Documents, and as otherwise
permitted in accordance with the Finance Documents, may deem necessary or advisable to accomplish the purposes hereof and thereof, which appointment as
attorney-in-

  
 -101- 

 § 8.3(a) 

 

	 	
fact is coupled with an interest and is irrevocable and, without limiting the generality of the foregoing, which appointment hereby gives the Security Trustee the power and right on behalf of or
for the benefit of the Securing Parties and each Secured Party without notice to or assent by any of the foregoing, to the extent permitted by applicable law, to do the following when and to the extent it is authorized or directed to do so pursuant
to the terms of this Agreement or any of the other Finance Documents: 

  

	 	(i)	in the name of such Collateral Party or its own name to ask for, demand, sue for, collect, receive and give acquittance for any and all monies due or to become due with respect to the Collateral (including any insurance
proceeds); 

  

	 	(ii)	in the name of such Collateral Party or its own name to receive, take, endorse, assign and deliver any and all checks, notes, drafts, acceptances, any bills of exchange, invoices, freight or express bills, storage or
warehouse receipts, bills of lading, money orders, assignments, verifications, notices, documents and other negotiable and non-negotiable Instruments and Chattel Paper or other instruments for the payment of
money; 

  

	 	(iii)	to commence, file, prosecute, defend, settle, compromise, adjust, revoke, cancel, annul, move to dismiss or otherwise undo any claim, suit, action or proceeding with respect to the Security Interests granted for the
benefit of the Secured Parties in the Collateral; 

  

	 	(iv)	to pay or discharge taxes and Liens levied or placed on or threatened against the Collateral, perform any obligation of such Collateral Party hereunder or under any other Finance Document or any Assigned Agreement, make
payments, submit drawing certificates under any letter of credit, purchase, contest or compromise any encumbrance, charge or Lien and pay expenses of such Collateral Party, effect any repairs, process, replace, alter, add, improve, preserve and/or
protect the Collateral or, subject to and in accordance with Schedule L (Schedule of Minimum Insurance) of the Common Terms Agreement, to effect any insurance called for by the terms of the Finance Documents and pay all or any part of the
premiums therefor and the costs thereof; 

  

	 	(v)	to sell, transfer, assign or otherwise deal in or with the Collateral or any part thereof pursuant to the terms and conditions of this Agreement, the Security Documents and the other Finance Documents;

  

	 	(vi)	proceed to protect and enforce the rights vested in it by this Agreement and under the UCC; 

  

	 	(vii)	foreclose or enforce any agreement or instrument by or under or pursuant to which the Senior Debt Obligations are issued or secured; 

  
 -102- 

 § 8.3(a)(viii) 

 

	 	(viii)	incur reasonable and documented expenses, including attorneys’ fees, consultants’ fees and other reasonable costs appropriate to the exercise of any right or power under this Agreement or under any other
Finance Document, which incurrence shall be in accordance with the terms of Section 23.4 (Expenses) of the Common Terms Agreement and any comparable provision in any other Senior Debt Instrument then in effect; 

 

	 	(ix)	in connection with any acceleration and foreclosure, take possession of the Collateral and of any and all books of account and records of such Collateral Party relating to any of the Collateral and render it usable and
repair and/or renovate the same without, however, any obligation to do so, and enter upon, or authorize its designated agent to enter upon, the Project Facilities or any other location where the same may be located for that purpose (including the
right, to the extent permitted by Government Rules, of the Security Trustee to exclude such Collateral Party and all Persons claiming access through such Collateral Party from any access to the Collateral or to any part thereof) and the Security
Trustee and its representatives are hereby granted an irrevocable license to enter upon such premises for such purpose, and to hold, control, manage, operate, rent and lease the Collateral, collect all rents, issues, profits, fees, revenues and
other income from the Collateral and apply the same as provided for in the Intercreditor Agreement; 

  

	 	(x)	subject to Articles 6 (Security Trustee Action) and 7 (Intercreditor Arrangements), defend any suit, action or proceeding brought against such Collateral Party with respect to any Collateral;

  

	 	(xi)	subject to Articles 6 (Security Trustee Action) and 7 (Intercreditor Arrangements), make any reasonable compromise or settlement deemed desirable with respect to any of the Collateral or any suit, action
or proceeding related thereto and, in connection therewith, extend the time of payment, arrange for payment installments, or otherwise modify the terms of, any Collateral; 

 

	 	(xii)	subject to Articles 6 (Security Trustee Action) and 7 (Intercreditor Arrangements), secure the appointment of a receiver of the Collateral or any part thereof, whether incidental to a proposed sale of the
Collateral or otherwise, and all disbursements made by such receiver and the expenses of such receivership shall be added to and be made a part of the Senior Debt Obligations, and, whether or not said principal sum, including such disbursements and
expenses, exceeds the indebtedness originally intended to be secured hereby, the entire amount of said sum, including such disbursements and expenses, shall be secured by this Agreement and shall be due and payable upon demand therefor and
thereafter shall bear interest in the same manner as Senior Debt Obligations under the Finance Documents or the maximum rate permitted by applicable Government Rules, whichever is less; 

  
 -103- 

 § 8.3(a)(xix) 

 

	 	(xiii)	subject to Articles 6 (Security Trustee Action) and 7 (Intercreditor Arrangements) enter into any extension, reorganization, deposit, merger, consolidation or other agreement pertaining to, or deposit,
surrender, accept, hold or apply other property in exchange for, the Collateral or any part thereof; 

  

	 	(xiv)	subject to Articles 6 (Security Trustee Action) and 7 (Intercreditor Arrangements) transfer the Collateral or any part thereof to the name of the Security Trustee or to the name of the Security
Trustee’s nominee; 

  

	 	(xv)	subject to Articles 6 (Security Trustee Action) and 7 (Intercreditor Arrangements) execute (in the name, place and stead of such Collateral Party) endorsements, assignments and other instruments of
conveyance or transfer with respect to all or any of the Collateral; 

  

	 	(xvi)	to do, at its option and at the expense and for the account of the Securing Parties, at any time and from time to time, all acts and things which the Security Trustee deems necessary or advisable to protect or preserve
the Collateral and to realize upon such Collateral (including to file financing statements, continuation statements and any such documents as may be necessary or that may be reasonably required by the Security Trustee to evidence the Security
Interests); 

  

	 	(xvii)	subject to Articles 6 (Security Trustee Action) and 7 (Intercreditor Arrangements) make formal application for the transfer of all or any of the Permits relating to the Collateral or to such Collateral
Party’s business to the Security Trustee or to any assignee of the Security Trustee or to any purchaser of any of the Collateral; 

  

	 	(xviii)	subject to Articles 6 (Security Trustee Action) and 7 (Intercreditor Arrangements) appoint another Person (who may be an employee, officer or other representative of the Security Trustee) to do any of the
foregoing, or take any other action permitted hereunder, as agent for or representative of, and on behalf of, the Security Trustee; or 

  

	 	(xix)	subject to Articles 6 (Security Trustee Action) and 7 (Intercreditor Arrangements) exercise any other or additional rights or remedies granted to the Security Trustee under any other provision under this
Agreement or any Finance Document, or exercisable by a secured party under the UCC (whether or not the UCC is in effect in the jurisdiction where the rights and remedies are asserted) and such additional rights and remedies to which a secured party
is entitled under the laws in effect in any jurisdiction where any rights and remedies hereunder may be asserted, including the right, to the fullest extent permitted by applicable law, to exercise all voting, consensual and other powers of
ownership pertaining to the Collateral as if the Security Trustee were the sole and absolute owner thereof (and such Collateral Party agrees to take all such action as may be appropriate to give effect to such right). 

  
 -104- 

 § 8.3(a)(xix) 

 

	 	(b)	The power of attorney in clause (a) above shall be deemed to have been issued and delivered in The City of New York, in the State of New York. The Collateral Parties and each Secured Party agrees to (and the
Securing Parties shall procure that any Securing Party shall), if required by applicable law or reasonably requested by the Security Trustee, execute and deliver to the Security Trustee a notarized public deed constituting such power of attorney.

  

	 	(c)	Each Secured Party and Senior Creditor Group Representative agrees, if required by applicable law or reasonably requested by the Security Trustee, to execute and deliver to the Security Trustee a notarized public deed
appointing the Security Trustee and any officer or agent thereof, with full power of substitution, its attorney-in-fact for purposes of exercising the rights and
remedies of such Secured Party under this Agreement and the other Finance Documents that the Security Trustee is authorized to take pursuant to this Agreement. 

  

	 	(d)	Other than in the case of fraud, gross negligence or willful misconduct determined by a court of competent jurisdiction in a final and non-appealable judgment, any action or
decision made by the Security Trustee in accordance with any Finance Document shall be binding as between the Security Trustee and the Secured Parties. 

  

	 	8.4	Reliance 

  

	 	(a)	The Security Trustee shall be entitled to conclusively rely and to act upon any notice, certificate, instrument, demand, request, direction, instruction, waiver, receipt, consent, agreement or other document or
communication furnished hereunder (including, for the avoidance of doubt, any advice obtained pursuant to Section 8.6 (Consultation with Counsel, Etc.)) or under the other Finance Documents which it in good faith believes and on its face
appears to be genuine, and it shall be entitled to rely upon the due execution, validity and effectiveness, and the truth and acceptability, of any provisions contained therein. 

 

	 	(b)	The Security Trustee shall have no requirement or obligation to make any commitment or to make any inquiry as to the nature or sufficiency of any payment received by the Security Trustee, or to present or file any claim
or notice, or to take any action with respect to the Collateral or any part thereof or the moneys due or to become due in respect thereof or any property covered thereby. The Security Trustee may assume that no Event of Default and/or default or
termination event under any Permitted Senior Debt Hedging Instrument has occurred and that no party is in breach of its obligations under any Finance Document unless the Security Trustee receives specific written notice to the contrary.

  
 -105- 

 § 8.4(c) 

 

	 	(c)	The Security Trustee shall have no obligation to familiarize itself with and shall have no responsibility with respect to any agreement or document (other than this Agreement and any other Finance Document to which the
Security Trustee, in its capacity as such, is party) relating to the transactions contemplated by the Finance Documents (except such sections of such agreements or documents referred to herein or therein) nor any obligation to inquire whether any
notice, certificate, instrument, demand, request, direction, instruction, waiver, receipt, consent, document, communication, statement or calculation is in conformity with the terms of any such agreement or document, except those irregularities or
errors of which the Security Trustee has actual knowledge, and provided that nothing herein shall constitute a waiver by any Securing Party or the Secured Parties of any of their rights against the Security Trustee as a result of its gross
negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in a final non-appealable judgment. If any remittance or communication received by the Security Trustee appears
manifestly erroneous or irregular to the Security Trustee, it shall be under a duty to make prompt inquiry to the Person originating such remittance or communication in order to determine whether a clerical error or inadvertent mistake has occurred.

  

	 	(d)	Each Collateral Party, each Secured Party and each Senior Creditor Group Representative shall deliver to the Security Trustee a list of authorized signatories, together, in the case of the Collateral Parties, with a
certificate of an officer of such party certifying the names and true signatures of such authorized signatories who are authorized to sign any notice, certificate, instrument, demand, request, direction, instruction, waiver, receipt, consent,
agreement or other document or communication furnished to the Security Trustee hereunder or under the other Finance Documents and the Security Trustee shall be entitled to rely conclusively on such list until a new list is furnished by a Collateral
Party, a Secured Party or a Senior Creditor Group Representative, as the case may be, to the Security Trustee. 

  

	 	(e)	The Secured Parties shall communicate to the Security Trustee in respect of the Collateral only through the relevant Senior Creditor Group Representative. 

 

	 	(f)	All communications by a Secured Party to the Collateral Parties in respect of the relevant Security Interest in connection with the Security Documents or the Direct Agreements shall be made through the Security Trustee.

  

	 	8.5	Liability 

  

	 	(a)	 Neither the Security Trustee nor its directors, officers or employees nor any authorized representatives, agents,
attorneys, Receivers or other Persons permitted or authorized to act in accordance with or pursuant to the Security Documents and/or the Direct Agreements shall be liable for any error of judgment or for any action taken, suffered or omitted by it
in good faith or for any mistake of fact or law, or for any act which it may do or refrain from doing in good faith and reasonably believed by it to be authorized or within the discretion or rights or powers conferred upon it by this Agreement
(including actions taken or omitted 

  
 -106- 

 § 8.5(a) 

 

	 	
by the Security Trustee in accordance with a direction or directions received by it from Senior Creditor Group Representatives representing the percentage of Senior Debt Obligations required
hereby for the giving of any such direction(s)), except as a result of its own gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in a final non-appealable
judgment. 

  

	 	(b)	Nothing in any Finance Document shall, in any case in which the Security Trustee has failed to show the degree of care and diligence required of it as trustee having regard to the provisions of the Finance Documents
conferring on it any trusts, powers, authorities or discretions, exempt the Security Trustee from or indemnify it against any liability arising out of its own gross negligence, fraud or willful misconduct in relation to its duties under the Finance
Documents as determined by a court of competent jurisdiction in a final non-appealable judgment. 

  

	 	(c)	Subject to Section 8.6(c) (Consultation with Counsel, Etc.), the Security Trustee shall not be responsible for the negligence or misconduct of any representative, agent, attorney, Receiver or any other
Person permitted or authorized to act in accordance with or pursuant to the Security Documents and/or the Direct Agreements; provided that nothing herein shall constitute a waiver by any Securing Party or the Secured Parties of any of their
rights against (i) the Security Trustee or (ii) such representative, agent, attorney, Receiver or other Person, in each case as a result of its gross negligence, fraud or willful misconduct as determined by a court of competent
jurisdiction in a final non-appealable judgment. 

  

	 	(d)	Except as expressly set forth herein and in the other Finance Documents, the Security Trustee shall have no duty to disclose, and shall not be liable for the failure to disclose, any information relating to the Securing
Parties or any Affiliate of a Securing Party that is communicated to or obtained by the Security Trustee, or any of its Affiliates, in any capacity. 

  

	 	8.6	Consultation with Counsel, Etc. 

  

	 	(a)	The Security Trustee may consult with, obtain and rely on advice or services from, legal counsel, accountants, investment bankers and other experts, subject, with respect to legal counsel, to the requirements of clause
(b) below and with respect to the Consultants, to the requirements of Article 13 (Consultants) of the Common Terms Agreement (whether obtained by the Security Trustee or by any other Secured Party, and with the reasonably incurred cost
thereof in each case at the expense of the Securing Parties), in connection with the performance of its duties hereunder or under the other Finance Documents and, notwithstanding any monetary or other limit on liability in respect thereof, it shall
incur no liability and shall be fully protected in acting in good faith in accordance with the written opinion and advice of such counsel, accountants and other experts. 

  
 -107- 

 § 8.6(b) 

 

	 	(b)	The Security Trustee shall only be entitled to the reimbursement of legal fees and expenses for the use of only one law firm engaged for all of the Secured Parties in each relevant jurisdiction unless (i) one or
more of the Secured Parties incurring such fees and expenses reasonably believes that there is a reasonable likelihood of a conflict of interest between any of them (the existence of which shall be notified to the Company) necessitating the use of
more than one law firm in any such jurisdiction or (ii) one or more of the Secured Parties requests reimbursement for the use of more than one law firm in each relevant jurisdiction, for any reason explained in reasonable detail to the Company,
and the Company has consented in advance (such consent not to be unreasonably withheld or delayed). 

  

	 	(c)	The Security Trustee shall not be responsible for the negligence or misconduct of any counsel, accountants and other experts selected by it in good faith, and shall not be required to make any investigation as to the
accuracy or sufficiency of any such advice or services; provided that nothing herein shall constitute a waiver by the Collateral Parties or the Secured Parties of any of their rights against (A) the Security Trustee as a result of its
gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in a final, non-appealable judgment or (B) such counsel, accountants or other experts. 

 

	 	8.7	Resignation, Removal and Replacement of Security Trustee 

  

	 	(a)	Subject to the appointment and acceptance of a successor Security Trustee as provided below, the Security Trustee may at any time resign as Security Trustee hereunder and under any other Finance Document to which it is
a party upon giving notice in writing to the Company and each Senior Creditor Group Representative. 

  

	 	(b)	The Security Trustee may be removed as Security Trustee hereunder by an instrument in writing by (x) for so long as the Common Terms Agreement is outstanding, the Intercreditor Agent and (y) at any other time,
the Senior Creditor Group Representatives representing the Majority in Interest of the Senior Creditors. 

  

	 	(c)	Upon the resignation or removal of the Security Trustee, a successor Security Trustee shall be appointed by an instrument in writing executed by (x) for so long as the Common Terms Agreement is outstanding, the
Intercreditor Agent and (y) at any other time, the Senior Creditor Group Representatives representing the Majority in Interest of the Senior Creditors, and (unless a Declared Event of Default is Continuing) such appointment shall be
subject to the consent of the Company (such consent not to be unreasonably withheld or delayed). Any such successor Security Trustee shall be required to have an office in the State of New York. 

  
 -108- 

 § 8.7(d)(i) 

 

	 	(d)	No resignation or removal of the Security Trustee and no appointment of a successor trustee shall be effective until: 

  

	 	(i)	the successor trustee has accepted its appointment and has acknowledged and accepted its rights and responsibilities hereunder and under the Security Documents and other Finance Documents; 

 

	 	(ii)	all then due and payable indemnities, compensation and expenses required by Sections 8.8 (Indemnity), 8.9 (Compensation and Expenses) and 8.11 (Stamp and Other Similar Taxes) to the existing
Security Trustee shall have been paid or provided for; and 

  

	 	(iii)	the Security Trustee shall have executed and delivered, at the Securing Parties’ expense, to the successor trustee such deeds, delegations of power or other instruments or documents as are required to transfer its
rights and responsibilities hereunder and under the Security Documents and other Finance Documents, including the powers of attorney under Section 8.3
(Attorney-in-Fact). 

  

	 	(e)	If no successor Security Trustee shall have been so appointed and shall have accepted such appointment within 60 days after (i) the retiring Security Trustee gives notice of its resignation or (ii) the date
fixed for such removal, as applicable, the Security Trustee shall, at the expense of the Securing Parties, petition any court of competent jurisdiction in the United States for the appointment of a successor Security Trustee. Such court may
thereupon, after such notice, if any, as it may prescribe, appoint a successor Security Trustee. If no successor Security Trustee shall have been so appointed in accordance with clauses (a) through (d) above or (A) this
clause (e) and shall have accepted such appointment within 90 days or (B) in the case of this clause (e) if the Security Trustee, acting reasonably, cannot determine a court of competent jurisdiction in the United States that will
consider the petition contemplated in this clause (e) within 60 days, in each case after (x) the retiring Security Trustee gives notice of its resignation or (y) the date fixed for such removal, as applicable, the Security Trustee
may, at the expense of the Securing Parties, appoint a successor Security Trustee; provided that if no successor Security Trustee shall have been so appointed by the Security Trustee within 30 days after the termination of such 90-day period, the Securing Parties may, at their own expense, appoint a successor Security Trustee with the consent of the Intercreditor Agent (not to be unreasonably withheld). Any successor Security Trustee
appointed pursuant to this Section 8.7 (Resignation, Removal and Replacement of Security Trustee) shall be a financial institution of good standing that has (1) all of the corporate, trust, banking and other powers necessary to
carry out the functions of the Security Trustee under this Agreement, the other Security Documents and the other Finance Documents and (2) a combined capital and surplus of at least $1 billion or an affiliate of such financial institution.

  

	 	(f)	 Any successor Security Trustee shall evidence its acceptance of the appointment hereunder by executing and
delivering to the Company, each Senior Creditor Group Representative and the Security Trustee an Accession Agreement substantially in the form of Schedule D-2 (Forms of Accession Agreements –
Form of Security Trustee Accession Agreement) 

  
 -109- 

 § 8.7(f) 

 

	 	
(together with one or more certificates as to the due authorization, execution and delivery of the Accession Agreement and incumbency of the officers or attorneys-in-fact who executed the Accession Agreement) accepting its appointment as Security Trustee hereunder and under the Security Documents and the other Finance Documents, and upon the date defined in
the Accession Agreement as its effective date, such successor Security Trustee, without any further act, deed or conveyance, shall become vested with all the rights, powers, duties and obligations of its predecessor hereunder and under the Security
Documents and the other Finance Documents with like effect as if originally named as Security Trustee herein and therein, and such predecessor shall have no further obligation or liability thereunder except for liability with respect to its acts or
omissions prior to such succession pursuant to Section 8.5 (Liability). Section 8.8 (Indemnity) shall continue in effect for the benefit of such predecessor in respect of any actions taken or omitted to be taken by it while
it was acting as Security Trustee. 

  

	 	(g)	The Security Trustee ceasing to act shall, at the expense of the Securing Parties, execute and deliver instruments transferring to such successor trustee all rights and powers of the Security Trustee so ceasing to act,
including any such instruments necessary to assign the rights under this Agreement, the Security Documents and the other Finance Documents and to transfer any Project Property held by it to such successor trustee, and shall deliver to such successor
trustee all property held by it in trust hereunder. 

  

	 	8.8	Indemnity 

  

	 	(a)	The Securing Parties agree to indemnify (without duplication in respect of any other indemnity required under Section 12.18 (Other Indemnities) or any other Finance Document) the Security Trustee in its
individual capacity and its directors, officers, agents and employees, and any Receiver properly appointed under a Security Document or Direct Agreement for, and to hold each of them harmless against, any loss, liability, claim, judgment,
settlement, compromise, obligation, damage, penalty, cost, expense or disbursement of any kind or nature whatsoever (including reasonable attorneys’ fees and expenses): 

 

	 	(i)	with respect to the execution, delivery, enforcement, performance and administration of this Agreement, the Security Documents and the other Finance Documents; or 

 

	 	(ii)	by reason of any defense, set-off, counterclaim, recoupment or reduction of liability whatsoever claimed in any suit, proceeding or action brought by the Security Trustee in its
individual capacity by an obligee under any Finance Document that (A) arises out of a breach by any Collateral Party of any of its obligations hereunder or thereunder or (B) arises out of any other agreement, indebtedness or liability at
any time owed to such obligee or its successors from any Collateral Party (which, for the avoidance of doubt, shall be and remain enforceable against and only against such Collateral Parties, and shall not be enforceable against the Security Trustee
(in its individual or any other capacity)), 

  
 -110- 

 § 8.8(a)(ii) 

 

 unless arising from the gross negligence, fraud or willful misconduct of the Security
Trustee or the Persons that are seeking indemnification, as determined by a court of competent jurisdiction in a final non-appealable judgment, including the costs and expenses of defending itself against any
claim of liability in the premises. To the extent that the undertakings to defend, indemnify, pay and hold harmless set forth in this Section 8.8 (Indemnity) may be unenforceable in whole or in part because they are violative of any law
or public policy, the Company shall contribute the maximum portion that it is permitted to pay and satisfy under applicable law to the payment and satisfaction of all indemnified liabilities incurred by the Security Trustee and its directors,
officers, agents and employees or any of them. 
  

	 	(b)	Without limiting the liability of the Securing Parties under the Finance Documents, if the Securing Parties fail to comply with their obligations under clause (a) above, each Senior Creditor shall (based on the
proportion of indebtedness owed to it by the Securing Parties relative to the aggregate indebtedness owed by the Securing Parties to all Senior Creditors under the Senior Debt Instruments and Permitted Senior Debt Hedging Instruments) indemnify the
Security Trustee, within five Business Days of demand, against any loss, liability, claim, judgment, settlement, compromise, obligation, damage, penalty, cost, expense or disbursement of any kind or nature whatsoever (including reasonable
attorneys’ fees and expenses) incurred by the Security Trustee with respect to the execution, delivery, enforcement, performance and administration of this Agreement and the other Finance Documents, unless arising from the Security
Trustee’s gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in a final non-appealable judgment. 

 

	 	(c)	The Securing Parties shall, within five Business Days of demand (but without duplication of indemnification otherwise received by the Security Trustee from the Securing Parties), reimburse each Senior Creditor for any
payment made by it under clause (b) above upon production of a certificate from each such Senior Creditor setting out the details of such payment and all such amounts shall comprise “Senior Debt Obligations.” 

 

	 	(d)	If the Security Trustee requests the assistance of a Secured Party: 

  

	 	(i)	during a time when an Event of Default or an Unmatured Event of Default has occurred and is Continuing; or 

  

	 	(ii)	otherwise with the Company’s consent, 

  
 -111- 

 § 8.8(e) 

 

 to consult on behalf of or for the benefit of the Secured Parties with the Security Trustee,
the provisions of Section 8.1(c) (Appointment and Duties) and Section 8.5 (Liability) shall apply to such Secured Party as though it were the Security Trustee and such Secured Party shall be entitled to indemnification under
this Section 8.8 (Indemnity). Such Secured Party shall have no responsibility or obligation to provide such assistance unless it elects to do so, and upon such election shall have no obligations unless it benefits from the indemnity and
exoneration provisions as contemplated by this clause (d). 
  

	 	(e)	If any indemnity furnished to the Security Trustee for any purpose shall, in the reasonable opinion of the Security Trustee, be insufficient or become impaired, the Security Trustee may call for additional indemnity and
cease, or not commence, to do the acts indemnified against until such additional indemnity is furnished; provided that in no event shall this sentence require any Senior Creditor to indemnify the Security Trustee against any liability,
obligation, loss, damage, penalty, action, judgment, suit, cost, expense or disbursement in excess of such Senior Creditor’s pro rata share thereof; provided, further, that this sentence shall not be deemed to require any
Senior Creditor to indemnify the Security Trustee against any liability, obligation, loss, damage, penalty, action, judgment, suit, cost, expense or disbursement arising from the Security Trustee’s gross negligence, fraud or willful misconduct,
as determined by a court of competent jurisdiction in a final non-appealable judgment. 

  

	 	(f)	The agreements in Section 8.5 (Liability) and this Section 8.8 (Indemnity) shall survive resignation or removal of the Security Trustee, as the case may be, and the termination of the other
provisions of this Agreement. 

  

	 	(g)	Without prejudice to the other provisions of this Section 8.8 (Indemnity), the Security Trustee and every Receiver, attorney, manager, agent or other Person appointed by the Security Trustee hereunder or
under any other Security Document or Direct Agreement shall be entitled to be indemnified out of the Collateral in respect of all liabilities and expenses properly incurred by it or any one of them in the execution or purported execution of this
Agreement or of any functions vested in it or any one of them pursuant to this Agreement, the Security Documents and any of the other Finance Documents and against all actions, proceedings, costs, claims and demands against it by third parties in
respect of any acts or omissions relating to the Collateral, and the Security Trustee may retain any part of any monies held by it as a result of the operation or application of this Agreement, the Security Documents and any of the other Finance
Documents constituting all sums necessary to effect such indemnity and also the remuneration of the Security Trustee. 

  

	 	(h)	In no event shall the Security Trustee be liable for any loss of profits, goodwill, reputation, business, opportunity or anticipated saving, or for special, punitive or consequential damages, whether or not the Security
Trustee has been advised of the possibility of such loss or damages. 

  
 -112- 

 § 8.9 
  

	 	8.9	Compensation and Expenses 

  

	 	(a)	The Security Trustee shall be entitled to such compensation (which shall not be limited by any provision of law in regard to compensation of a trustee of an express trust) for all services rendered by the Security
Trustee under this Agreement, the Security Documents and the other Finance Documents payable by the Securing Parties, as has been agreed from time to time between the Securing Parties and the Security Trustee in the SG Agency Fee Letter. Fees and
expenses payable to the Security Trustee for its services under this Agreement and pursuant to the SG Agency Fee Letter shall be paid free and clear of, and without any deduction or withholding for or on account of, any current or future taxes,
levies, imposts, duties, charges or other deductions or withholdings levied in any jurisdiction from or through which payment is made, unless such deduction or withholding is required by applicable law, in which event the Securing Parties shall pay
additional amounts (other than with respect to taxes, levies, imposts, duties, charges or other deductions or withholdings imposed on or measured by net income and resulting from a present or former connection of the Security Trustee to such
jurisdiction) so that the Security Trustee will receive the amount that it would otherwise have received but for such deduction or withholding after allowing for any deductions or withholding attributable to additional amounts payable under this
Agreement. Any Senior Debt Obligations paid to the Security Trustee shall be subject to the tax gross-up and indemnity provisions of the applicable Senior Debt Instrument (including, if applicable, Article 21
(Tax Gross-Up and Indemnities) of the Common Terms Agreement). 

  

	 	(b)	The Security Trustee shall be entitled to reimbursement in its individual capacity, without duplication in respect of any other indemnity and/or expense reimbursement required under any other Finance Document, upon
receipt by the Company of reasonable evidence (by invoice or other written evidence), for its reasonable advances, disbursements and expenses in connection with the performance of its duties hereunder (including the reasonable fees and expenses of
its agents, any Receiver properly appointed under a Security Document or Direct Agreement and of counsel, accountants and other experts referred to in Section 8.6 (Consultation with Counsel, Etc.)) and under the Security Documents and
any other Finance Documents (including (1) for the protection, preservation, repair or recovery of the Collateral (including payment of Taxes or purchasing insurance for the Collateral), (2) for the protection of the interest of the
Security Trustee in the Collateral and (3) for the collection of indebtedness secured hereby and by the other Security Documents or enforcement of the Security Trustee’s remedies hereunder and under the other Security Documents following
and during the Continuance of an Event of Default), and interest thereon, from time to time as services are rendered and advances, disbursements and expenses are incurred. 

 

	 	(c)	The Secured Parties shall have no liability for any fees, expenses or disbursements of the Security Trustee, but without prejudice to the obligations of the Secured Parties under Section 8.8 (Indemnity).

  
 -113- 

 § 8.10 
  

	 	8.10	Certificates 

 Whenever in the performance of its respective duties under this Agreement,
the Security Documents or the other Finance Documents, the Security Trustee in good faith shall deem it necessary or desirable that a matter be proved or established in connection with taking or omitting to take any action by the Security Trustee
hereunder, under the Security Documents, or under any other Finance Document, such matter (unless other evidence in respect thereof be herein specifically prescribed) may, in the absence of gross negligence, fraud or willful misconduct on the part
of the Security Trustee, as determined by a court of competent jurisdiction in a final non-appealable judgment, be deemed to be conclusively proved or established by a written certificate of the relevant
Securing Party, Holdco or the relevant Senior Creditor Group Representative delivered to the Security Trustee, and the Security Trustee need not call for further evidence and shall not be responsible for any loss occasioned by acting on such a
certificate. 
  

	 	8.11	Stamp and Other Similar Taxes 

  

	 	(a)	The Securing Parties agree to indemnify and hold harmless the Security Trustee (in its capacity as such hereunder) and each other Secured Party from, and shall reimburse the Security Trustee and each other Secured Party
for, any present or future claim for liability for any stamp, duty, registration, excise, property and other similar Taxes, including any penalties, additions, fines, surcharges or interest relating thereto, which may be assessed, levied or
collected by any jurisdiction in connection with this Agreement, the other Security Documents and the other Finance Documents, the trust created hereunder or the attachment or perfection of the Security Interests granted to the Security Trustee in
any Collateral. 

  

	 	(b)	The obligations of the Securing Parties under this Section 8.11 (Stamp and Other Similar Taxes) shall survive the termination of this Agreement. 

 

	 	(c)	Without in any way limiting the Securing Parties’ obligations pursuant to clause (a) above, each party hereto agrees that it shall undertake in good faith to avoid bringing, causing to be brought, or knowingly
permitting to be brought any executed part or any copy of this Agreement into any jurisdiction, if as a result thereof any stamp duty, tax or other like charge would be incurred; provided that it is understood among the parties and the
Securing Parties hereby expressly acknowledge and agree that the Secured Parties or a Senior Creditor Group Representative may take any such action (or direct the Security Trustee to take such action), irrespective of the stamp duty, tax or other
charge which may be incurred as a result thereof if such action, in such Person’s reasonable judgment, is necessary or advisable for the purposes of the enforcement of this Agreement, the other Security Documents and the other Finance Documents
or compliance with any order or direction of any governmental authority or the preservation of the Collateral or the rights and remedies of the Secured Parties. 

  
 -114- 

 § 8.12 
  

	 	8.12	Information 

 The Company agrees that, from time to time upon the reasonable request of
the Security Trustee, it shall deliver to the Security Trustee a list setting forth, by each Senior Debt Instrument or Permitted Senior Debt Hedging Instrument, as applicable: 
  

	 	(a)	the aggregate principal amount outstanding thereunder; and 

  

	 	(b)	the interest rate then in effect thereunder. 

  

	 	8.13	Books and Records 

 The Security Trustee shall maintain all such accounts, books and
records as may be reasonably necessary to record properly all transactions carried out by it under this Agreement, the Security Documents, and the other Finance Documents. If permitted by applicable law and regulation, the Security Trustee shall
provide the Securing Parties with any information or document relevant to such accounts, books and records as they may reasonably request from time to time. 
  

	 	8.14	Limitation on Security Trustee’s Duties in Respect of Collateral 

  

	 	(a)	Beyond its express duties set forth in this Agreement, the Security Documents or the other Finance Documents as to the custody thereof and the accounting to the Collateral Parties and the Secured Parties for monies
received hereunder, the Security Trustee shall not have any duty to the Collateral Parties or the Secured Parties with respect to any Collateral in its possession or control or in the possession or control of its agent or nominee, any income
thereon, or the priority or preservation of rights against prior parties or any other rights pertaining thereto. 

  

	 	(b)	To the extent that the Security Trustee or an agent or nominee of the Security Trustee maintains possession or control of any of the Collateral, the Security Documents or the Direct Agreements at any office of the
Security Trustee, the Security Trustee shall, or shall instruct such agent or nominee to, grant the Collateral Parties or the Secured Parties and the Senior Creditor Group Representatives access to such Collateral, Security Documents or Direct
Agreements which they require for the conduct of their businesses, except, in the case of the Collateral Parties, if and to the extent that the Security Trustee shall have commenced a Security Enforcement Action. 

 

	 	8.15	Security Documents 

 Without prejudice to Section 8.5 (Liability), the
Security Trustee shall not be liable for any failure, omission, or defect in perfecting the Security Interests, including any failure: 
  

	 	(a)	to register the same in accordance with the provisions of any of the documents of title of a Securing Party (or Holdco, as appropriate) to any of the property thereby charged; 

  
 -115- 

 § 8.15(b) 

 

	 	(b)	to make any recordings or filings or re-recordings or re-filings in connection therewith; 

 

	 	(c)	to take, or to require a Securing Party (or Holdco, as appropriate) to take, any steps to perfect its title to any assets subject to any Security Documents or to render the Security Interests effective or to secure the
creation of Security Interests under the laws of any jurisdiction; 

  

	 	(d)	to give notice to any Person of the execution of any of the Security Documents or the Direct Agreements; or 

  

	 	(e)	to obtain any license, consent or other authority for the creation of the Security Interests. 

  

	 	8.16	Exculpatory Provisions 

 The Security Trustee makes no representations as to the value or
condition of the Collateral or any part thereof, or as to the title of any Collateral Party thereto or as to the rights and interests granted or the security afforded in this Agreement or any other Finance Document or as to the validity, execution
(except by itself), enforceability, legality or sufficiency of this Agreement, any Security Document, any other Finance Document or the Senior Debt Obligations, and the Security Trustee shall incur no liability or responsibility in respect of any
such matters. 
  

	 	8.17	Own Responsibility 

 Each Secured Party understands and agrees that it has itself been,
and will continue to be, solely responsible for making its own independent appraisal of, and investigations into, the financial condition, creditworthiness, condition, affairs, status and nature of each party to each Finance Document and,
accordingly, each such Secured Party warrants to the Security Trustee that it has not relied on, and will not rely on, the Security Trustee: 
  

	 	(a)	to check or inquire on its behalf into the adequacy, accuracy or completeness of any information provided by any Person under or in connection with any Finance Document (whether or not such information has been, or is,
circulated to such Person by the Security Trustee); 

  

	 	(b)	to assess or review on its behalf the financial condition, solvency, creditworthiness, condition, affairs, status or nature of any Person; or 

 

	 	(c)	to assess or make any investigation as to the right or title of any person in or to, or the value or sufficiency of, any part of the Collateral, the priority of any of the Collateral or the existence of any Security
Interest affecting the Collateral. 

  
 -116- 

 § 8.18(a) 

 

	 	8.18	Merger of the Security Trustee 

  

	 	(a)	Any corporation into which the Security Trustee in its individual capacity shall be merged, or with which it shall be consolidated, or any corporation resulting from any merger or consolidation to which the Security
Trustee (in its individual capacity) shall be a party, shall be the Security Trustee under this Agreement, the Security Documents, and any other Finance Document, without the execution or filing of any paper or any further act on the part of the
parties hereto; provided that such party shall meet the requirements of Section 8.7 (Resignation, Removal and Replacement of Security Trustee). 

 

	 	(b)	The Security Trustee shall provide the Company and the Senior Creditor Group Representatives with prompt notice of a merger pursuant to clause (a) above. 

 

	 	8.19	Treatment of Senior Creditors by the Security Trustee 

  

	 	(a)	The Security Trustee may treat the Holders of the Senior Debt Obligations as the absolute owners thereof for all purposes unless the Security Trustee shall receive notice to the contrary. 

 

	 	(b)	Only the Intercreditor Agent and the Senior Creditor Group Representatives designated in accordance with this Agreement shall act as the duly authorized representatives of Senior Creditors with authority to act as such
in connection with any matters pertaining to this Agreement, any Security Document, or any other Finance Document or the Collateral. 

  

	 	8.20	Compliance 

  

	 	(a)	None of the provisions of this Agreement, the Security Documents or the other Finance Documents shall be construed to require the Security Trustee to do anything which may be illegal or contrary to law or regulation.
The Security Trustee may do anything which, in its reasonable opinion, is necessary or desirable to comply with any law or regulation. The Security Trustee may refrain from doing anything that, in its reasonable opinion, is contrary to any Finance
Document. 

  

	 	(b)	The Security Trustee shall be under no obligation to exercise any of the rights or powers vested in it in this Agreement, the Security Documents or the other Finance Documents, at the request or direction of any
Securing Party or any Senior Creditor or Senior Creditor Group Representative, unless the Security Trustee shall have been offered security or indemnity and/or pre-funding reasonably satisfactory to it against
the costs, expenses and liabilities which might be incurred by it in compliance with such request or direction (including interest thereon from the time incurred until reimbursed). 

 

	 	(c)	The Security Trustee shall not be liable for any failure or delay in the performance of its obligations under this Agreement, the Security Documents or any other Finance Documents if it is prevented from so performing
by an act of God or any other force majeure event. 

  
 -117- 

 § 8.21 
  

	 	8.21	Miscellaneous 

  

	 	(a)	The rights, powers, entitlements and authorities of the Security Trustee arising under this Agreement, any Security Document or any other Finance Document shall be in addition to any such rights, powers, entitlements
and authorities arising by applicable law. 

  

	 	(b)	The Security Trustee shall have the right at any time to seek instructions concerning the administration of this Agreement from any court of competent jurisdiction in the United States. 

 

	 	(c)	If the Security Trustee is also a Senior Creditor or Senior Creditor Group Representative, the Security Trustee shall have the same rights and powers under this Agreement, any Security Document, and any other Finance
Document as any other Senior Creditor or Senior Creditor Group Representative, as the case may be, and may exercise those rights as though it were not the Security Trustee. 

 

	 	(d)	The Security Trustee may in its individual capacity (or for any parent, subsidiary or associated Person) accept deposits from, lend money to, and generally engage in any kind of banking or other business with, any
Collateral Party, any other Secured Party, the Account Bank, or any of their Affiliates, and retain any profits or remuneration in connection with its activities under the Finance Documents or in relation to any of the foregoing, without affecting
the right to enforce any Senior Debt Obligations or other right to payment or Security Interest created hereunder or pursuant hereto as freely as if it were not the Security Trustee hereunder. The Security Trustee shall notify the Company and each
Senior Creditor Group Representative at any time it believes it has any interest conflicting with its obligations hereunder. 

  

	 	(e)	The Security Trustee in its individual capacity hereby waives any right of banker’s lien, set-off or counterclaim in respect of any assets contained in the Accounts or
otherwise that are held by the Security Trustee as Security Trustee hereunder. 

  

	 	(f)	 Except to the extent that this Agreement, any Security Document and any other Finance Document expressly
contemplates that the Security Trustee is allowed to act through agents or other third parties, the Security Trustee shall not delegate, assign or otherwise transfer any of its obligations, duties or responsibilities hereunder without the prior
written consent of (x) for so long as the Common Terms Agreement is outstanding, the Intercreditor Agent and (y) at any other time, the Senior Creditor Group Representatives representing the Majority in Interest of the Senior Creditors;
provided that no such consent shall be required in connection with the enforcement of remedies hereunder on behalf of or for the benefit of the Senior Creditors and no such consent shall be unreasonably withheld or delayed. The Security
Trustee shall not be responsible for the acts or omissions of any such agents or third parties selected by it in good faith; provided that nothing herein shall constitute a waiver by the Collateral Parties or the

  
 -118- 

 § 8.21(f) 

 

	 	
Secured Parties of any of their rights against (A) the Security Trustee as a result of its gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in
a final non-appealable judgment or (B) such agents or third parties appointed by the Security Trustee. 

  

	 	(g)	The Security Trustee may, in the absence of any instructions to the contrary, take such action in the exercise of any of its powers and duties under the Finance Documents which it considers reasonably necessary or
advisable for the protection and benefit of the Secured Parties. 

  

	9.	THE ACCOUNT BANK 

  

	 	9.1	Appointment and Role of the Account Bank 

  

	 	(a)	As of the date of this Agreement, the Company has appointed Mizuho Bank, Ltd. as the Account Bank and Mizuho Bank, Ltd. hereby accepts such appointment and agrees to act as the Account Bank under the express terms of
this Agreement. The Security Trustee and each Senior Creditor Group Representative hereby acknowledge and consent to such appointment. 

  

	 	(b)	The parties hereby agree that the Account Bank shall only be responsible for performing the functions expressly set forth in this Agreement as being those of the Account Bank. 

 

	 	9.2	Undertakings of the Account Bank 

  

	 	(a)	The Account Bank shall, in relation to each Account: 

  

	 	(i)	comply with all instructions given to it and provide such information as may be required from it in relation to the Accounts pursuant to the provisions of Article 4 (Cash Flow and Accounts); 

 

	 	(ii)	not permit any Account to be closed without the prior consent of the Security Trustee (acting upon instructions from each Senior Creditor Group Representative); 

 

	 	(iii)	act upon any instruction given by the Security Trustee in accordance with this Agreement; and 

  

	 	(iv)	in the event of any conflict between the terms of this Agreement and any mandate or any other agreements entered into with the Company at any time and notwithstanding any provisions of such mandates and agreements that
would purport to resolve any conflict between that mandate or agreement and this Agreement in favor of that mandate or agreement (including but not limited to Section 6.9 of the Funds Transfer Agreement), treat this Agreement as taking
precedence. 

  
 -119- 

 § 9.2(b) 

 

	 	(b)	Subject to the rights reserved to the Account Bank in Section 3.2(d)(vii) (Security Interests to be Granted by the Securing Parties – Provisions Related to Secured Accounts), the Account Bank in its
individual capacity hereby waives any right of banker’s lien, set-off or counterclaim in respect of any assets contained in the Accounts or otherwise that are held by the Account Bank hereunder.

  

	 	9.3	No Fiduciary Duties 

 Nothing in this Agreement constitutes the Account Bank as a trustee
or fiduciary of any other Person. The Account Bank shall not be bound to account to any other Secured Party for any sum or the profit element of any sum received by it for its own account. 

 

	 	9.4	The Account Bank Individually 

  

	 	(a)	If it is also a Senior Creditor, the Account Bank shall have the same rights and powers under this Agreement and each other Finance Document as any other Senior Creditor and may exercise those rights and powers as
though it were not the Account Bank. 

  

	 	(b)	The Account Bank may: 

  

	 	(i)	accept deposits from, lend money to, and generally engage in any kind of banking or other business with, any Collateral Party, any other Secured Party or any of their Affiliates; and 

 

	 	(ii)	retain any profits or remuneration in connection with its activities under the Finance Documents or in relation to any of the foregoing. 

 

	 	9.5	Rights and Discretions of the Account Bank 

  

	 	(a)	The Account Bank may conclusively rely on: 

  

	 	(i)	any representation, notice or other document which it in good faith believes to be genuine and correct and to have been signed by, or with the authority of, the proper Person; and 

 

	 	(ii)	any statement made by a director, authorized signatory or employee of any Person regarding any matters which may reasonably be assumed to be within his or her knowledge or within his or her power to verify.

  

	 	(b)	The Account Bank may assume (unless it has received notice to the contrary in its capacity as Account Bank) that any right, power, authority or discretion vested in any Person or any group thereof has been validly
exercised. 

  

	 	(c)	Notwithstanding any other provision of any Finance Document to the contrary, the Account Bank is not obliged to do or omit to do anything if it would or might (in its reasonable opinion) constitute a breach of any law
or duty, including the duty of confidentiality. 

  
 -120- 

 § 9.5(d) 

 

	 	(d)	Notwithstanding anything to the contrary expressed or implied in any Finance Document, the Account Bank shall not: 

  

	 	(i)	be bound to monitor or inquire as to whether or not any representation made or deemed to be made by any Collateral Party thereof is true or as to the occurrence or otherwise of any Event of Default, the occurrence of
the Project Completion Date, or any other event or occurrence; 

  

	 	(ii)	be under any obligations other than those which are specifically provided for in this Agreement, and no implied duties or covenants shall be read against the Account Bank (other than any obligations that are not
waivable under any applicable laws); or 

  

	 	(iii)	be bound to exercise any right, power or discretion vested in it under any of the Finance Documents unless instructed or otherwise required to do so in accordance with this Agreement. 

 

	 	(e)	Upon receiving instructions from the Company or the Security Trustee, as the case may be, to make payments out of an Account, the Account Bank may assume that all conditions specified in this Agreement and in any other
Finance Documents to the making of any payment out of any Account have been satisfied unless it has actual knowledge or actual notice to the contrary in its capacity as the Account Bank. 

 

	 	(f)	The Account Bank may assume (unless it has received a notice from the Security Trustee pursuant to Section 4.6(b)(i) (Control and Investment of Funds in Accounts)) that no Event of Default has occurred and
that any proposed withdrawal is permitted by this Agreement and the other Finance Documents, but shall not be obliged to give effect to any notice of withdrawal if to give such notice effect would or might (in its reasonable opinion) breach the
terms of this Agreement. 

  

	 	(g)	If the Account Bank receives a notice from the Security Trustee pursuant to Section 4.6(b)(i) (Control and Investment of Funds in Accounts), the Account Bank will disregard any conflicting directions,
notices or other documents it receives from the Company until a notice is delivered by the Security Trustee to the Account Bank pursuant to and in accordance with Section 4.6(c) (Control and Investment of Funds in Accounts) with respect
to the relevant Declared Event(s) of Default. 

  

	 	(h)	 The Account Bank shall have no obligation to familiarize itself with and shall have no responsibility with
respect to any agreement or document (other than the terms of this Agreement relating to the rights and duties of the Account Bank) relating to the transactions contemplated by the Finance Documents nor any obligation to inquire whether any notice,
certificate, instrument, demand, request, direction, instruction, waiver, receipt, consent, document, communication, statement or calculation is in conformity with the terms of such agreement or

  
 -121- 

 § 9.5(h) 

 

	 	
document, except those errors manifestly apparent on the face of such document or of which the Account Bank has actual knowledge; provided that nothing herein shall constitute a waiver by
the Company or the Secured Parties of any of their rights against the Account Bank as a result of its gross negligence, fraud or willful misconduct as determined by a court of competent jurisdiction in a final
non-appealable judgment. If any remittance or communication received by the Account Bank appears manifestly erroneous to the Account Bank in the judgment of the Account Bank, the Account Bank may make an
inquiry to the Person originating such remittance or communication in order to determine whether a clerical error or inadvertent mistake has occurred. 

  

	 	(i)	The Account Bank may consult with, and obtain and rely on advice or services from, legal counsel, accountants and other experts, subject, with respect to legal counsel, to the same requirements as those set forth with
respect to legal counsel of the Security Trustee in Section 8.6(b) (Consultation with Counsel, Etc.) and with respect to the Consultants, to the requirements of Article 13 (Consultants) of the Common Terms Agreement (whether
obtained by the Account Bank or by any other Secured Party, and with the reasonably incurred cost thereof in each case at the expense of the Securing Parties), in connection with the performance of its duties hereunder or under the other Finance
Documents and, notwithstanding any monetary or other limit on liability in respect thereof, it shall incur no liability and shall be fully protected in acting in good faith in accordance with the written opinion and advice of such counsel,
accountants and other experts. 

  

	 	9.6	No Responsibility for Documentation 

 The Account Bank is not responsible for: 

 

	 	(a)	the execution (other than its own execution of this Agreement), genuineness, validity, adequacy, enforceability, admissibility in evidence or sufficiency of any Finance Document or any other document; 

 

	 	(b)	the collectability of amounts payable under any Finance Document; or 

  

	 	(c)	the adequacy, accuracy and/or completeness of any statements (whether written or oral) made in, or in connection with, any Finance Document, with the exception of any statements made by the Account Bank in this
Agreement with respect to itself. 

  

	 	9.7	Exclusion of Liability 

  

	 	(a)	 The Account Bank shall not be liable to any other party for any action taken or not taken by it under, or in
connection with, this Agreement or any other Finance Document unless directly caused by its gross negligence, fraud or willful misconduct, as determined by a court of competent jurisdiction in a final
non-appealable judgment. The Account Bank shall not otherwise be liable or responsible for any liabilities or inconvenience which may result from anything done or omitted to be done by it in connection with
this Agreement. Liabilities 

  
 -122- 

 § 9.7(a) 

 

	 	
arising under this clause shall be limited to the amount of the Securing Parties’ actual loss (such loss shall be determined as at the date of default of the Account Bank or, if later, the
date on which the loss arises as a result of such default) but without reference to any special conditions or circumstances not known to the Account Bank at the time of entering into the Agreement, or at the time of accepting any relevant
instructions, which increases the amount of the loss. In no event shall the Account Bank be liable for any loss of profits, goodwill, reputation, business opportunity or anticipated saving, or for special, punitive or consequential damages, whether
or not the Account Bank has been advised of the possibility of such loss or damages. 

  

	 	(b)	None of the provisions of this Agreement, the Security Documents, or the other Finance Documents shall be construed to require the Account Bank to do anything which may (i) be illegal or contrary to law or
regulation or (ii) cause it to expend or risk its own funds or otherwise to incur any financial liability in the performance of any of its duties hereunder or thereunder if it shall have reasonable grounds for belief that repayment of such
funds or indemnity against such risk or liability is not reasonably assured to it. The Account Bank shall be excused from taking any action hereunder in the circumstances described in the preceding sentence. 

 

	 	9.8	Indemnities 

  

	 	(a)	The Securing Parties agree to indemnify (without duplication in respect of any other indemnity required under Section 12.18 (Other Indemnities) or any other Finance Document) the Account Bank in its
individual capacity and its directors, officers, agents, employees and Affiliates for, and to hold each of them harmless against, any loss, liability, claim, judgment, settlement, compromise, damage, penalty, cost, expense or disbursement of any
kind or nature whatsoever (including reasonable attorneys’ fees and expenses) with respect to the execution, delivery, enforcement, performance and administration of this Agreement, the Security Documents and the other Finance Documents, unless
arising from the gross negligence, fraud, or willful misconduct of the Account Bank or the Persons that are seeking indemnification as determined by a court of competent jurisdiction in a final non-appealable
judgment, including the costs and expenses of defending itself against any claim of liability in the premises. To the extent that the undertakings to defend, indemnify, pay and hold harmless set forth in this Section 9.8 (Indemnities)
may be unenforceable in whole or in part because they are violative of any law or public policy, the Securing Parties shall contribute the maximum portion that such parties are permitted to pay and satisfy under applicable law to the payment and
satisfaction of all indemnified liabilities incurred by the Account Bank and its directors, officers, agents and employees or any of them. 

  
 -123- 

 § 9.8(e) 

 

	 	(b)	Without limiting the liability of the Securing Parties under the Finance Documents, if the Securing Parties fail to comply with their obligations under clause (a) above, each Senior Creditor shall (based on the
proportion of indebtedness owed to it by the Company relative to the aggregate indebtedness owed by the Company to all Senior Creditors under the Senior Debt Instruments and Permitted Senior Debt Hedging Instruments) indemnify the Account Bank (and
its directors, officers, agents, employees and Affiliates), within five Business Days of demand, against any loss, liability, claim, judgment, settlement, compromise, obligation, damage, penalty, cost, expense or disbursement of any kind or nature
whatsoever (including reasonable attorneys’ fees and expenses) incurred by the Account Bank or such related Persons with respect to the execution, delivery, enforcement, performance and administration of this Agreement and the other Finance
Documents, unless arising from the Account Bank’s or such Person’s gross negligence, fraud, or willful misconduct, as determined by a court of competent jurisdiction in a final non-appealable
judgment. 

  

	 	(c)	The Securing Parties shall, within five Business Days of demand (but without duplication of indemnification otherwise received by the Account Bank or a Senior Creditor from the Company), reimburse each Senior Creditor
for any payment properly made by it under clause (b) above upon production of a certificate from each such Senior Creditor setting out the details of such payment. 

 

	 	(d)	The provisions of Section 9.7 (Exclusion of Liability) and this Section 9.8 (Indemnities) shall survive the resignation of the Account Bank pursuant to Section 9.9 (Resignation, Removal
and Replacement of the Account Bank) and the termination of the other provisions of this Agreement. 

  

	 	(e)	The Company agrees that, subject to Article 4 (Cash Flow and Accounts) and the other terms of this Article 9 (The Account Bank), the Account Bank may act upon any instruction, including any telex,
facsimile or email instructions, that are received by the Account Bank from Persons that are or which are reasonably believed by the Account Bank to be authorized by the Company, the Manager or the Security Trustee, as the case may be. The Securing
Parties agree to indemnify and hold the Account Bank (and its directors, officers, agents, employees and Affiliates) harmless from any claims by virtue of the Account Bank’s acting upon any instruction, such as any telex, facsimile or email
instructions, as such instructions were understood by the Account Bank, except for claims relating solely from the Account Bank’s or such Person’s gross negligence, fraud or willful misconduct, as determined by a court of competent
jurisdiction in a final non-appealable judgment. The Account Bank shall not be liable for any errors in the transmission or the illegibility of any telexed, telecopied or emailed documents. In the event the
Company sends the Account Bank a manually signed confirmation of the previously sent telex, facsimile or email instructions, the Account Bank shall have no duty to compare it against the previous instructions received by the Account Bank nor shall
the Account Bank have any responsibility should the contents of the written confirmation differ from the telex, facsimile or email instructions acted upon by the Account Bank. 

  
 -124- 

 § 9.8(g) 

 

	 	(f)	In no event shall the Account Bank be liable for any claims, losses, liabilities, damages, costs, expenses and judgments (including legal fees and expenses) sustained by any party arising to it from receiving or
transmitting any data from the Company or any Person authorized to act on behalf of the Company (including the Manager and any Person so authorized by the Manager) or the Security Trustee, as the case may be, via any
non-secure method of transmission or communication, such as, but without limitation, by facsimile or email, except for any such claims relating solely from the Account Bank’s gross negligence, fraud, or
willful misconduct as determined by a court of competent jurisdiction in a final non-appealable judgment. The Company accepts that some methods of communication are not secure, and the Account Bank shall incur
no liability for receiving instructions from Persons purporting to be, or which instructions appear to be authorized by, the Company or the Security Trustee, as the case may be, via any such non-secure method.
The Account Bank is authorized to comply with and rely upon any such notice, instructions or other communications purported to have been sent by a Person authorized by the Company or the Security Trustee, as the case may be. The Company shall use
all reasonable endeavors to ensure that instructions transmitted to the Account Bank pursuant to this Agreement are complete and correct. Any such instructions shall be conclusively deemed to be valid instructions from the Company or the Security
Trustee, as the case may be, to the Account Bank for the purposes of this Agreement. The Account Bank has no duty or obligation to investigate the authenticity or correctness of the matters stated in any instruction, notice or other document from
the Company or the Security Trustee, or to confirm that the signatories on the instruction, notice or document were properly appointed. 

  

	 	(g)	If any indemnity furnished to the Account Bank for any purpose shall, in the reasonable opinion of the Account Bank, be insufficient or become impaired, the Account Bank may call for additional indemnity and cease, or
not commence, to do the acts indemnified against until such additional indemnity is furnished; provided that in no event shall this sentence require any Senior Creditor to indemnify the Account Bank against any liability, obligation, loss,
damage, penalty, action, judgment, suit, cost, expense or disbursement in excess of such Senior Creditor’s pro rata share thereof; provided, further, that this sentence shall not be deemed to require any Senior Creditor to
indemnify the Account Bank against any liability, obligation, loss, damage, penalty, action, judgment, suit, cost, expense or disbursement arising from the Account Bank’s gross negligence, fraud or willful misconduct, as determined by a court
of competent jurisdiction in a final non-appealable judgment. 

  

	 	(h)	The Account Bank shall not be liable for any failure or delay in the performance of its obligations under this Agreement, the Security Documents or any other Finance Documents if it is prevented from so performing by an
act of God or any other force majeure event. 

  
 -125- 

 § 9.9(c) 

 

	 	9.9	Resignation, Removal and Replacement of the Account Bank 

  

	 	(a)	(i) Subject to the appointment and acceptance of a successor Account Bank, the Account Bank may resign as Account Bank hereunder by giving written notice to the Company and each Senior Creditor Group Representative or
(ii) so long as no Event of Default has occurred and is Continuing, the Company may remove the Account Bank as Account Bank hereunder by giving not less than 30 days’ written notice to the Account Bank and each Senior Creditor Group
Representative. 

  

	 	(b)	Any successor Account Bank shall be approved by (x) for so long as the Common Terms Agreement is outstanding, the Intercreditor Agent, and (y) at any other time, the Senior Creditor Group Representatives
representing the Majority in Interest of the Senior Creditors. 

  

	 	(c)	If no successor Account Bank shall have been so appointed in accordance with clauses (a) and (b) above and shall have accepted such appointment within 60 days after (i) the retiring Account Bank has given
notice of its resignation or (ii) the date fixed for such removal, as applicable, the Account Bank may, at the expense of the Securing Parties, petition any court of competent jurisdiction in the United States for the appointment of a successor
Account Bank. Such court may thereupon, after such notice, if any, as it may prescribe, appoint a successor Account Bank. If no successor Account Bank shall have been so appointed in accordance with clauses (a) and (b) above or
(A) this clause (c) and shall have accepted such appointment within 90 days or (B) in the case of this clause (c) if the Account Bank, acting reasonably, cannot determine a court of competent jurisdiction in the United States
that will consider the petition contemplated in this clause (c) within 60 days, in each case after (x) the retiring Account Bank gives notice of its resignation or (y) the date fixed for such removal, as applicable, the Account Bank
may, at the expense of the Securing Parties, appoint a successor Account Bank; provided, that if no successor Account Bank shall have been so appointed by the Account Bank within 30 days after the termination of such 90-day period, the Company may, at the expense of the Securing Parties, appoint a successor Account Bank with the consent of the Intercreditor Agent (not to be unreasonably withheld, taking into account the
requirements applicable to an Account Bank). Any successor Account Bank appointed pursuant to this clause (c) shall be a bank meeting the criteria in the definition of Account Bank. 

 

	 	(d)	The retiring or removed Account Bank shall, at the Company’s cost and expense, make available to the successor Account Bank such documents and records and provide such assistance as the successor Account Bank may
reasonably request for the purposes of performing its functions as Account Bank under the Finance Documents, and any amounts standing to the credit of the Accounts maintained by the retiring or removed Account Bank shall be transferred to the
corresponding accounts opened on the books of the successor Account Bank. 

  
 -126- 

 § 9.9(h) 

 

	 	(e)	The resignation or removal of the Account Bank and the appointment of the successor Account Bank shall become effective only upon the execution and delivery, to the Company and the Security Trustee, by the successor
Account Bank of: 

  

	 	(i)	an Accession Agreement substantially in the form of Schedule D-3 (Forms of Accession Agreements – Form of Account Bank Accession Agreement) acceding to this
Agreement; 

  

	 	(ii)	one or more certificates as to the due authorization, execution and delivery of the Accession Agreement and incumbency of the officers or
attorneys-in-fact who executed the Accession Agreement; and 

  

	 	(iii)	such acknowledgements and other documentation as may be necessary or that may be reasonably required by the Security Trustee to maintain the Security Interests. 

 

	 	(f)	Upon the effective succession of a successor Account Bank, the retiring Account Bank shall have no further obligation or liability hereunder or under any Finance Document except for liability with respect to the acts or
omissions of such retiring Account Bank prior to such succession. Section 9.7 (Exclusion of Liability) shall continue in effect for the benefit of the retiring Account Bank in respect of any actions taken or omitted to be taken by it
while it was acting as Account Bank. The successor Account Bank and each of the other parties shall have the same rights and obligations amongst themselves as they would have had if such successor Account Bank had been an original party.

  

	 	(g)	The Account Bank agrees that it shall, if so requested in writing by any Senior Creditor Group Representative or the Company following the Account Bank’s ceasing to meet the requirements to be an Account Bank (as
specified in the definition of “Account Bank”), tender its resignation in accordance with this Section 9.9 (Resignation, Removal and Replacement of the Account Bank). 

 

	 	(h)	Any corporation or financial institution into which the Account Bank in its individual capacity shall be merged, or with which it shall be consolidated, or any corporation or financial institution resulting from any
merger or consolidation to which the Account Bank (in its individual capacity), or any corporation or financial institution succeeding to the corporate trust (or similar) business of the Account Bank shall be the Account Bank under this Agreement,
the Security Documents, and any other Finance Document, without the execution or filing of any paper or any further act on the part of the parties hereto; provided that such party shall meet the requirements of this Section 9.9
(Resignation, Removal and Replacement of the Account Bank). 

  
 -127- 

 § 9.10(a) 

 

	 	9.10	Notice and Acknowledgment of Security 

  

	 	(a)	Each Securing Party hereby gives notice to the Account Bank that it has charged to the Security Trustee all of its right, title and interest in the Accounts, and all cash, Financial Assets or other property now or
hereafter credited thereto, or held therein, and investments (including any Authorized Investments) made with or arising out of such funds, and all proceeds of the foregoing, as provided in Section 3.2(a) (Security Interests to be Granted by
the Securing Parties – Pledge of Pledged Collateral), Section 3.2(b) (Security Interests to be Granted by the Securing Parties – Security Interests – General) and Section 3.2(c) (Security Interests to be
Granted by the Securing Parties – Security Interests – Individual Senior Noteholder Secured Accounts). 

  

	 	(b)	The Account Bank acknowledges the notice of grant of a Security Interest from the Securing Parties set forth herein in respect of each Account and acknowledges that it has not prior to the date hereof received notice of
any previous assignments of Liens over or trusts in respect of such Accounts. 

  

	 	9.11	Compensation and Expenses 

  

	 	(a)	The Account Bank shall be entitled to such compensation for all services rendered by the Account Bank under this Agreement, the Security Documents and the other Finance Documents, payable by the Company, as may be
agreed from time to time between the Company and the Account Bank. 

  

	 	(b)	The Account Bank shall be entitled to reimbursement in its individual capacity, without duplication in respect of any other indemnity and/or expense reimbursement required under any other Finance Document, upon receipt
by the Company of reasonable evidence (by invoice or other written evidence), for its reasonable advances, disbursements and expenses in connection with the performance of its duties hereunder and under the Security Documents and any other Finance
Documents, from time to time as services are rendered and advances, disbursements and expenses are incurred. 

  

	 	(c)	The Secured Parties shall have no liability for any fees, expenses or disbursements of the Account Bank, except to the extent provided for in Section 9.8 (Indemnities). 

 

	10.	OBLIGATIONS UNDER SECURITY DOCUMENTS 

  

	 	10.1	Nature of Obligations 

  

	 	(a)	 This Agreement and the Senior Debt Obligations shall continue to be effective or be automatically reinstated, as
the case may be, if (and to the extent that) any payment or performance of the Senior Debt Obligations by the Company or any discharge given by a Secured Party (whether in respect of the obligations of the Company or any security for those
obligations or otherwise) is rescinded, avoided, voidable, liable to be set aside, reduced or otherwise not properly payable to, or must be returned or restored by the Security Trustee or any other Secured Party (i) as a result of Bankruptcy,
insolvency, reorganization with respect to the Company or any Collateral Party, (ii) upon the dissolution of, or appointment of any intervenor, conservator, trustee or similar official for the

  
 -128- 

 § 10.1(b) 

 

	 	
Company, any Collateral Party or for any substantial part of the Company’s or any other such Person’s assets, (iii) as a result of any settlement or compromise with any Person
(including the Company) in respect of such payment or otherwise, or (iv) as a result of any similar event or otherwise and, in such case: 

  

	 	(i)	the liability of the Company shall continue as if the payment or discharge in the amount so rescinded, reduced, restored or returned had not occurred; 

 

	 	(ii)	such Senior Debt Obligations shall be reinstated on the same terms and conditions applicable thereto prior to the payment of the rescinded, reduced, restored or returned amount, and shall be deemed reduced only by such
amount paid and not so rescinded, reduced, restored or returned; and 

  

	 	(iii)	each Secured Party shall be entitled to recover the value or amount of that security or payment from the Company as if the payment or discharge in the amount so rescinded, reduced, restored or returned had not occurred.

  

	 	(b)	Subject to Article 11 (Guarantees), the obligations of the Collateral Parties under this Agreement and the other Finance Documents shall not be affected by any act, omission, matter or thing which, but for this
Section 10.1 (Nature of Obligations), would reduce, release or prejudice any of such obligations (whether or not known to it or to any Secured Party), including: 

 

	 	(i)	any change in the time, manner or place of payment of, or in any other term of the Senior Debt Obligation (including any increase in the amount thereof); 

 

	 	(ii)	any rescission; waiver, amendment or modification of, or any consent to departure from, any of the terms or provisions (including provisions relating to events of default) hereof, any of the other Finance Documents or
any agreement or instrument executed pursuant thereto, or of any other guaranty or security for the Senior Debt Obligations, in each case whether or not in accordance with the terms hereof or such Finance Document or any agreement relating to such
other guaranty or security; 

  

	 	(iii)	the release of any other Person under the terms of any agreements or arrangement with any creditor; 

  

	 	(iv)	any exchange, surrender, release or non-perfection of any Collateral, or any exchange, surrender, release, non-perfection, amendment or
waiver or addition of or consent to departure from any other security interest held by any Secured Party or of any Lien on other collateral for all or any of the Senior Debt Obligations or any avoidance of any Lien; 

 

	 	(v)	any change in the corporate existence, structure or ownership of the Collateral Parties, or any Bankruptcy of the Collateral Parties; 

  
 -129- 

 § 10.1(b)(x) 

 

	 	(vi)	any unenforceability, illegality or invalidity of any Finance Document, Senior Debt Obligation, Security Interest or any other agreement or instrument relating thereto; 

 

	 	(vii)	any other circumstance whatsoever which may in any manner or to any extent vary the risk of any Collateral Party as an obligor in respect of the Senior Debt Obligations or which constitutes, or might be construed to
constitute, an equitable or legal discharge of any Collateral Party for the Senior Debt Obligations, or of such Collateral Party under this Agreement or any other Finance Document or of any other Security Interest granted by any Collateral Party,
whether in a Bankruptcy Proceeding or in any other instance; 

  

	 	(viii)	the exercise by any Secured Party of any remedy, power or privilege contained in any Finance Document or available at law, equity or otherwise; 

 

	 	(ix)	any action by the Security Trustee to take and hold security or Collateral for the payment of the Senior Debt Obligations, or to sell, exchange, release, dispose of, or otherwise deal with, any property pledged,
mortgaged or conveyed, or in which the Security Trustee has been granted a Lien, to secure any indebtedness to the Security Trustee of any Securing Party, any of its Affiliates or any other Person party to a Transaction Document; 

 

	 	(x)	any reduction, limitation, impairment or termination of any of the Senior Debt Obligations for any reason other than payment or the written agreement of the Secured Parties to reduce, limit or terminate such Senior Debt
Obligations and each Securing Party hereby waives any right to or claim of, any defense or setoff, counterclaim, recoupment, or termination whatsoever by reason of the invalidity, illegality, nongenuineness, irregularity, compromise,
unenforceability of, or any other event or occurrence (other than the occurrence of the Discharge Date) affecting, any Senior Debt Obligation of any Securing Party, any Affiliate of such Securing Party or otherwise; 

 

	 	(xi)	the application of payments received from any source (other than payments received pursuant to the Finance Documents or from the proceeds of any security for the Senior Debt Obligations to the payment of indebtedness
other than the Senior Debt Obligations), even though any Secured Party might have elected to apply such payment to any part or all of the Senior Debt Obligations; 

 

	 	(xii)	any Bankruptcy of any Securing Party or any other Person; 

  
 -130- 

 § 10.1(b)(xiii) 

 

	 	(xiii)	any other circumstance which might otherwise constitute a defense available to, or a discharge of, any Securing Party (other than the defense of payment); or 

 

	 	(xiv)	any failure or omission to assert or enforce, or agreement or election not to assert or enforce, delay in enforcement, or stay or enjoining, by order of court, by operation of law or otherwise, of the exercise or
enforcement of any claim or demand or any right, power, remedy (whether arising under any Senior Debt Instrument, any Permitted Senior Debt Hedging Instrument, at law, in equity or otherwise) with respect to the Senior Debt Obligations or any
agreement relating thereto, or with respect to any other guaranty of or security for the payment of the Senior Debt Obligations. 

For the avoidance of doubt, this clause (b) is not intended to vitiate any express provision or written waiver granted by the Senior
Creditors under and in accordance with the Finance Documents, in each case in accordance with the express terms (and subject to any conditions or limitations) of such provisions or waivers. 

 

	 	(c)	Each Securing Party waives, to the maximum extent permitted by applicable Government Rules: 

  

	 	(i)	any right it may have of first requiring any Secured Party (or any trustee or agent on its behalf) to proceed against or enforce any other rights or security or claim payment from any Person, any security which the
Security Trustee may hold or any other remedy before making a claim on the Company or any other Securing Party; 

  

	 	(ii)	all rights under any law limiting remedies under an obligation secured by a mortgage or deed of trust on real property if the real property is sold under a power of sale contained in such mortgage or deed of trust;

  

	 	(iii)	all rights to require the Security Trustee to give any notices of any kind, including notices of nonpayment, nonperformance, protest, dishonor, default, delinquency or acceleration, or to make any presentments, demands
or protests, except as expressly set forth herein or as expressly provided in the Common Terms Agreement or other Finance Documents; and 

  

	 	(iv)	all defenses based on the disability or lack of authority of a Securing Party or any Person, the repudiation of the Finance Documents by Securing Party or any Person, the failure by the Security Trustee or the Secured
Parties to enforce any claim against such Securing Party, or the unenforceability in whole or in part of any Finance Documents. 

  

	 	(d)	Until all amounts which are due and payable by the Company to a Secured Party under or in connection with each Finance Document have been irrevocably paid in full, each such Secured Party (and any trustee or agent on
its behalf) may: 

  
 -131- 

 § 10.1(f) 

 

	 	(i)	refrain from applying or enforcing any other monies, security or rights held or received by that Secured Party (or any trustee or agent on its behalf) in respect of those amounts, or apply and enforce the same in such
manner and otherwise as it sees fit (whether against those amounts or otherwise), and the Company shall not be entitled to the benefit of the same; and 

  

	 	(ii)	hold in an interest-bearing suspense account any monies received from the Company or on account of the Company’s liability under the Finance Documents. 

 

	 	(e)	Until all amounts which may be, or become, payable by the Company under or in connection with the Finance Documents have been irrevocably paid in full and unless each of the Senior Creditor Group Representatives
otherwise directs, a Securing Party shall not exercise any rights which it may have by reason of performance by it of its obligations under the Finance Documents to take the benefit (in whole or in part and whether by way of subrogation or
otherwise) of any rights of the Secured Parties under the Finance Documents or of any other guarantee or security taken pursuant to, or in connection with, the Finance Documents by any Secured Party. 

 

	 	(f)	Each Securing Party acknowledges that, subject to the terms of this Agreement and the other Finance Documents, its liability and recourse to it and its assets hereunder and under such other Finance Documents shall
include any of its assets, wheresoever located. 

  

	 	10.2	Suspense Account 

 Unless instructed to the contrary in accordance with Section 6.3
(Conduct of Security Enforcement Action) and subject to Section 6.7 (Enforcement Proceeds Account), all monies received, recovered or realized by the Security Trustee under the Finance Documents (including prior to or following
any conversion of currency) may, in the discretion of the Security Trustee, be credited to a suspense account and held therein for so long as the Security Trustee may reasonably determine pending their conversion into another currency and/or
application from time to time in or towards satisfaction of the Senior Debt Obligations in accordance with the terms of this Agreement. 
  

	 	10.3	Limitation on Recourse 

  

	 	(a)	The Senior Debt Obligations are full recourse obligations of the Securing Parties, but are non-recourse to all Affiliates of the Securing Parties and their respective direct and
indirect members (including the Sponsor and its respective Affiliates), controlling Persons, directors, officers, employees or agents (collectively, the “Non-Recourse Persons”) except as set
forth in clause (b) below. 

  

	 	(b)	 Each Secured Party acknowledges and agrees that it shall have no claim against or recourse to any of the Non-Recourse Persons for the payment or performance of the Senior Debt Obligations or other obligations of the Securing Parties under the 

  
 -132- 

 § 10.3(b) 

 

	 	
Finance Documents, except for (i) Holdco, but solely to the extent of its obligations under the Security Documents and Direct Agreement(s) to which it is party and (ii) any claim
against a Non-Recourse Person for the recovery of any payment made to such Non-Recourse Person in breach of any of the Finance Documents. This clause (b) is not
intended to impair any contractual obligations that any Non-Recourse Person has undertaken for the benefit of any Senior Creditors under any Finance Document. 

 

	 	(c)	Nothing in this Section 10.3 (Limitation on Recourse) shall: 

  

	 	(i)	affect or diminish or constitute a waiver, release or discharge of any of the Senior Debt Obligations, or of any of the terms, covenants, conditions or provisions of this Agreement or any other Finance Document, and the
same shall continue until the Discharge Date or, if reinstated in accordance with Section 10.1(a) (Nature of Obligations), until fully paid in US Dollars, discharged, observed or performed; 

 

	 	(ii)	limit or restrict the right of the Secured Parties to name a Securing Party or any other Person as a defendant in any action or suit for a judicial foreclosure or for the exercise of any remedy under or with respect to
this Agreement or any other Finance Document, or for injunction or specific performance, so long as no judgment in the nature of a deficiency judgment shall be enforced against any Non-Recourse Person except
as set forth in this Section 10.3 (Limitation on Recourse); 

  

	 	(iii)	prevent the commencing of any action, suit or proceeding in respect of, or causing legal papers to be served upon any Person for the purpose of obtaining jurisdiction over, a Securing Party or any other Person;

  

	 	(iv)	in any way limit or restrict any right or remedy of the Secured Parties with respect to, and each of the Non-Recourse Persons shall remain fully liable to the extent that it would
otherwise be liable for, its own acts in connection with any fraud, gross-negligence or willful misappropriation of any earnings, revenues, rents, issues, profits or proceeds from the Collateral that should or would have been paid as provided in
this Agreement or any other Finance Document or paid or delivered to a Secured Party towards any payment required under this Agreement or any other Finance Document; or 

 

	 	(v)	affect or diminish or constitute a waiver, release or discharge of any specific written obligation, covenant or agreement in respect of any security interest granted by a
Non-Recourse Person in a Finance Document to which any Non-Recourse Person is a party or as security for the obligations of the Securing Parties. 

  
 -133- 

 § 10.4 
  

	 	10.4	No Interference; Payment Over; Exculpatory Provisions 

  

	 	(a)	Each Senior Creditor agrees that: 

  

	 	(i)	it shall not challenge or question or support any other Person in challenging or questioning in any proceeding the validity or enforceability of any Senior Debt Obligations or any Finance Document or the validity,
attachment, perfection or priority of any Lien under any Finance Document or the validity or enforceability of the priorities, rights or duties established by other provisions of this Agreement or the Security Documents; provided, that
nothing in this Agreement shall be construed to prevent or impair the rights of any Senior Creditor from challenging or questioning the validity or enforceability of any Senior Debt Obligations constituting unmatured interest or the validity of any
Lien relating thereto pursuant to Section 502(b)(2) of the Bankruptcy Code; 

  

	 	(ii)	it shall not take or cause to be taken any action the purpose or intent of which is, or could be, to interfere, hinder or delay, in any manner, whether by judicial proceedings or otherwise, any sale, transfer or other
disposition of the Collateral by the Security Trustee; 

  

	 	(iii)	except as provided herein and in the other Security Documents, it shall have no right to and shall not otherwise (A) direct the Security Trustee or any other Senior Creditor to exercise any right, remedy or power
with respect to any Common Collateral or (B) consent to, or object to, the exercise by, or any forbearance from exercising by, the Security Trustee or any other Senior Creditor represented by it of any right, remedy or power with respect to any
Collateral; 

  

	 	(iv)	it shall not institute any suit or assert in any suit, Bankruptcy Proceeding or other proceeding any claim against the Security Trustee or any other Senior Creditor represented by it seeking damages from or other relief
by way of specific performance, instructions or otherwise with respect to any Collateral; and 

  

	 	(v)	it shall not attempt, directly or indirectly, whether by judicial proceedings or otherwise, to challenge the enforceability of any provision of this Agreement; provided, that nothing in this Agreement shall be
construed to prevent or impair the rights of any of the Security Trustee or any other Senior Creditor (A) to enforce this Agreement and the other Finance Documents or (B) to contest or support any other Person in contesting the
enforceability of any Lien purporting to secure obligations not constituting Senior Debt Obligations. 

  
 -134- 

 § 10.5(a) 

 

	 	(b)	Each Senior Creditor hereby agrees that if it shall obtain possession of any Common Collateral or shall realize any proceeds or payment in respect of any Common Collateral pursuant to any Security Document or by the
exercise of any rights available to it under applicable law or in any insolvency or liquidation proceeding or through any other exercise of remedies (including pursuant to any intercreditor agreement), at any time prior to the discharge of the
Senior Debt Obligations in accordance with Section 12.1 (Termination), it shall hold such Common Collateral, proceeds or payment in trust for the other Senior Creditors having a Security Interest in such Common Collateral and promptly
transfer any such Common Collateral, proceeds or payment, as the case may be, to the Security Trustee, to be distributed by the Security Trustee in accordance with the provisions of Section 6.7 (Enforcement Proceeds Account) hereof;
provided, however, that the foregoing shall not apply to any Common Collateral purchased by any Senior Creditor for cash pursuant to any exercise of remedies permitted hereunder. 

 

	 	(c)	None of the Security Trustee, Intercreditor Agent, Account Bank, Senior Creditor Group Representatives or any Senior Creditor shall be liable for any action taken or omitted to be taken by the Security Trustee,
Intercreditor Agent, Account Bank, Senior Creditor Group Representatives or any Senior Creditor with respect to any Collateral in accordance with the provisions of this Agreement. 

 

	 	10.5	Certain Agreements with Respect to Bankruptcy 

  

	 	(a)	This Agreement shall continue in full force and effect notwithstanding the commencement of any Bankruptcy Proceeding or any other federal, state or foreign bankruptcy, insolvency, receivership or similar law by or
against any Collateral Party. 

  

	 	(b)	If any Collateral Party shall become subject to a Bankruptcy Proceeding and shall, as debtor(s)-in-possession, move for approval of
financing (“DIP Financing”) to be provided by one or more lenders (the “DIP Lenders”) under Section 364 of the Bankruptcy Code or the use of cash collateral under Section 363 of the Bankruptcy Code, each
Senior Creditor (other than any Controlling Claimholder) agrees as follows: 

  

	 	(i)	adequate notice to a Senior Creditor for such DIP Financing or use of cash collateral shall be deemed delivered to such Senior Creditor if such Senior Creditor receives notice five Business Days prior to the hearing to
approve such DIP Financing or use of cash collateral on an interim basis and at least fifteen days in advance of the hearing to approve such DIP Financing or use of cash collateral on a final basis; and 

 

	 	(ii)	 it will not raise any objection to any such financing or to the Liens on the Common Collateral securing the same
(“DIP Financing Liens”) or to any use of cash collateral that constitutes Common Collateral, unless the Controlling Claimholders shall then oppose or object to such DIP Financing or such DIP Financing Liens or use of cash collateral
(and (A) to the extent that such DIP Financing Liens are senior to the Liens on any such Common Collateral for the benefit of the Controlling 

  
 -135- 

 § 10.5(b)(ii) 

 

	 	
Claimholders, each Non-Controlling Claimholder will subordinate its Liens with respect to such Common Collateral on the same terms as the Liens of the
Controlling Claimholders (other than any Liens of any Senior Creditors constituting DIP Financing Liens) are subordinated thereto, and (B) to the extent that such DIP Financing Liens rank pari passu with the Liens on any such Common
Collateral granted to secure the Senior Debt Obligations of the Controlling Claimholders, each Non-Controlling Claimholder will confirm the priorities with respect to such Common Collateral as set forth
herein), in each case so long as (w) the Senior Creditors retain the benefit of their Liens on all such Common Collateral pledged to the DIP Lenders, including proceeds thereof arising after the commencement of such proceeding, with the same
priority vis-à-vis all the other Senior Creditors (other than any Liens of the Senior Creditors constituting DIP Financing Liens) as existed prior to the
commencement of the Bankruptcy Proceeding, (x) the Senior Creditors are granted Liens on any additional collateral pledged to any Senior Creditors as adequate protection or otherwise in connection with such DIP Financing or use of cash
collateral, with the same priority vis-à-vis the Senior Creditors as set forth in this Agreement (other than any Liens of any Senior Creditors constituting DIP
Financing Liens), (y) if any amount of such DIP Financing or cash collateral is applied to repay any of the Senior Debt Obligations, such amount is applied pursuant to Section 6.7 (Enforcement Proceeds Account) of this Agreement,
and (z) if any Senior Creditors are granted adequate protection with respect to the Senior Creditors subject hereto, including in the form of periodic payments, in connection with such use of cash collateral, the proceeds of such adequate
protection are applied pursuant to Section 6.7 (Enforcement Proceeds Account) of this Agreement; provided that the Senior Creditors shall have a right to object to the grant of a Lien to secure the DIP Financing over any
Collateral subject to Liens in favor of the Senior Creditors that shall not constitute Common Collateral; provided, further, that the Senior Creditors receiving adequate protection shall not object to any other Senior Creditor
receiving adequate protection comparable to any adequate protection granted to such Senior Creditors in connection with a DIP Financing or use of cash collateral. 

Nothing in this Section 10.5(b) limits or impairs the rights of the Senior Creditors to object to any motion regarding DIP Financing
(including a DIP Financing proposed by one or more Senior Creditors) or cash collateral to the extent that (1) the objection could be asserted in a Bankruptcy Proceeding by unsecured creditors generally, is consistent with the other terms of
this Section 10.5(b), and is not based on the status of a Senior Creditor as holder of a Lien, or (2) the DIP Financing does not meet the conditions of this Section 10.5(b). 

 

	 	(c)	 If any Senior Creditor is granted adequate protection (A) in the form of Liens on any additional collateral,
then each other Senior Creditor shall be entitled to seek, and each Senior Creditor will consent and not object to, adequate protection in the 

  
 -136- 

 § 11.1(c) 

 

	 	
form of Liens on such additional collateral with the same priority vis-à-vis the Senior Creditors as set
forth in this Agreement, (B) in the form of a superpriority or other administrative claim, then each other Senior Creditor shall be entitled to seek, and each Senior Creditor will consent and not object to, adequate protection in the form of a
pari passu superpriority or administrative claim or (C) in the form of periodic or other cash payments, then the proceeds of such adequate protection must be applied to all Senior Debt Obligations pursuant to Section 6.7
(Enforcement Proceeds Account). 

  

	11.	GUARANTEES 

  

	 	11.1	Guarantor Obligations 

 Each of the Guarantors hereby, jointly and severally, as a
primary obligor and not merely as a surety, unconditionally and irrevocably, guarantees to the Security Trustee, for the ratable benefit of each Secured Party and its respective successors and permitted endorsees, transferees and assigns, the prompt
and complete payment and performance by the Company when due (whether at the stated maturity, by acceleration or otherwise) of the Senior Debt Obligations under the Facility Agreements and other Finance Documents (including amounts that would become
due but for the operation of the automatic stay under Section 362(a) of the Bankruptcy Code or any equivalent provision in any applicable jurisdiction). 
  

	 	(a)	[Reserved]. 

  

	 	(b)	Each Guarantor agrees that the Senior Debt Obligations may at any time and from time to time exceed the amount of the liability of such Guarantor hereunder without impairing the guarantee contained in this Article 11
(Guarantees) or affecting the rights and remedies of any Secured Party hereunder. 

  

	 	(c)	Except for termination of a Guarantor’s obligations hereunder as expressly provided in Section 7.2(c) (Modification Approval Levels – Release of Collateral, Security Interests or Guarantees), the
guarantee contained in this Article 11 (Guarantees) shall remain in full force and effect, with respect to each Secured Party, until all Senior Debt Obligations and the obligations of each Guarantor under the guarantee contained in this
Article 11 (Guarantees) shall have been satisfied by payment in full. Each Guarantor hereby irrevocably waives any right to revoke this guarantee in respect of obligations under future transactions that constitute Senior Debt Obligations.

  

	 	(d)	 No payment made by any of the Securing Parties, any other guarantor or any other Person or received or collected
by any Secured Party from any of the Securing Parties, any other guarantor or any other Person by virtue of any action or proceeding or any set-off or appropriation or application at any time or from time to
time in reduction of or in payment of the Senior Debt Obligations under the Finance Documents shall be deemed to modify, reduce, release or otherwise affect the liability of any Guarantor hereunder, which shall, notwithstanding any

  
 -137- 

 § 11.1(d) 

 

	 	
such payment (other than any payment made by such Guarantor in respect of such Senior Debt Obligations or any payment received or collected from such Guarantor in respect of such Senior Debt
Obligations), remain liable for such Senior Debt Obligations up to the maximum liability of such Guarantor hereunder until such Senior Debt Obligations are paid in full. 

 

	 	11.2	Right of Contribution 

 Each Guarantor hereby agrees that to the extent that a Guarantor
shall have paid more than its proportionate share of any payment made hereunder, such Guarantor shall be entitled to seek and receive contribution from and against any other Guarantor hereunder which has not paid its proportionate share of such
payment. Each Guarantor’s right of contribution shall be subject to the terms and conditions of Section 11.4 (No Subrogation) below. The provisions of this Article 11 (Guarantees) shall in no respect limit the
obligations and liabilities of any Guarantor to the Secured Party, and each Guarantor shall remain liable to such Secured Party for the full amount guaranteed by such Guarantor hereunder. 

 

	 	11.3	Payment by Guarantors 

 Subject to Section 11.2 (Right of Contribution), each
Guarantor hereby jointly and severally agrees, in furtherance of the foregoing and not in limitation of any other right which any Secured Party may have at law or in equity against any Guarantor by virtue hereof, that upon the failure of the Company
to pay any of the Senior Debt Obligations when and as the same shall become due, whether at stated maturity, by required prepayment, declaration, acceleration, demand or otherwise (including amounts that would become due but for the operation of the
automatic stay under Section 362(a) of the Bankruptcy Code, 11 U.S.C. § 362(a) or any equivalent provision in any applicable jurisdiction), each Guarantor will upon demand pay, or cause to be paid, in cash, to the Security
Trustee for the ratable benefit of the Secured Parties, an amount equal to the sum of the unpaid principal amount of all Senior Debt then due as aforesaid, accrued and unpaid interest on Senior Debt Obligations (including interest which, but for the
Company becoming the subject of a case under the Bankruptcy Code or other similar legislation in any jurisdiction, would have accrued on such Senior Debt Obligations, whether or not a claim is allowed against the Company for such interest in the
related bankruptcy case) and all other Senior Debt Obligations then owed to the Secured Parties as aforesaid. 
  

	 	11.4	No Subrogation 

 Notwithstanding any payment made by any Guarantor hereunder or any set-off or application of funds of any Guarantor by any Secured Party, no Guarantor shall be entitled to be subrogated to any of the rights of any Secured Party against the Company or any other Guarantor or any
collateral security or guarantee or right of offset held by any Secured Party for the payment of the Senior Debt Obligations under any Senior Debt Instrument, nor shall any Guarantor seek or be entitled to seek any contribution or reimbursement from
the Company or any other Guarantor in respect of payments made 

  
 -138- 

 § 11.5(a) 

 

 
by such Guarantor hereunder, until all amounts owing to the Secured Parties by the Company on account of the Senior Debt Obligations are paid in full (as shown by payoff letter pursuant to
Section 12.1 (Termination)). If any amount shall be paid to any Guarantor on account of such subrogation rights at any time when all of the Senior Debt Obligations shall not have been paid in full, such amount shall be held by such
Guarantor in trust for the Security Trustee, on behalf of the Secured Parties, segregated from other funds of such Guarantor, and shall, forthwith upon receipt by such Guarantor, be turned over to Security Trustee in the exact form received by such
Guarantor (duly indorsed by such Guarantor to the Security Trustee, if required), to be applied against the Senior Debt Obligations, whether matured or unmatured, in such order as the Security Trustee may determine pursuant to Section 2.3
(Payments and Prepayments). 
  

	 	11.5	Amendments, etc. with respect to the Senior Debt Obligations 

 Each Guarantor shall
remain obligated hereunder notwithstanding that, without any reservation of rights against any Guarantor and without notice to or further assent by any Guarantor: 
  

	 	(a)	any demand for payment of any of the Senior Debt Obligations made by the Security Trustee may be rescinded by the Security Trustee in accordance with the Finance Documents and any such Senior Debt Obligations continued;

  

	 	(b)	the Senior Debt Obligations, or the liability of any other Person upon or for any part thereof, or any collateral security or guarantee therefor or right of offset with respect thereto, may, from time to time, in whole
or in part, be renewed, extended, amended, modified, accelerated, compromised, waived, surrendered, substituted or released by the Security Trustee or any Secured Party; and 

 

	 	(c)	this Agreement and the other Finance Documents and any other documents executed and delivered in connection therewith may be amended, modified, supplemented or terminated, in whole or in part pursuant to their terms,
and any collateral security, guarantee or right of offset at any time held by any Facility Agent or Facility Lender for the payment of such Senior Debt Obligations may be sold, exchanged, waived, surrendered or released. 

 

	 	11.6	Guarantee Absolute and Unconditional 

  

	 	(a)	The Senior Debt Obligations shall conclusively be deemed to have been created, contracted or incurred, or renewed, extended, amended or waived, in reliance upon the guarantee contained in this Article 11
(Guarantees); and all dealings between the Company and any of the Guarantors, on the one hand, and the Secured Parties, on the other hand, likewise shall be conclusively presumed to have been had or consummated in reliance upon the guarantee
contained in this Article 11 (Guarantees). Each Guarantor waives: 

  

	 	(i)	any and all notice of the creation, renewal, extension or accrual of any of the Senior Debt Obligations and notice of or proof of reliance by any Secured Party upon the guarantee contained in this Article 11
(Guarantees) or acceptance of the guarantee contained in this Article 11 (Guarantees); 

  
 -139- 

 § 11.6(a)(iv) 

 

	 	(ii)	diligence, presentment, protest, demand for payment, protest for nonpayment and notice of default or nonpayment to or upon any of the Securing Parties with respect to such Senior Debt Obligations; 

 

	 	(iii)	each and any right to require any Secured Party, as a condition of payment or performance by such Guarantor, to (A) proceed against the Company, any other guarantor (including any other Guarantor) of the Senior
Debt Obligations or any other Person, (B) proceed against or exhaust any Security Interest, any such other guarantor or any other Person, (C) proceed against or have resort to any balance of any Account or credit on the books of any
Secured Party in favor of any Securing Party or any other Person, or (D) pursue any other remedy in the power of any Secured Party whatsoever; 

  

	 	(iv)	any defense arising by reason of the lack of authority or any disability or other defense of the Company or any other Guarantor including any defense based on or arising out of the lack of validity or the
unenforceability of the Senior Debt Obligations or any agreement or instrument relating thereto or by reason of the cessation of the liability of the Company or any other Guarantor from any cause other than payment in full of the Senior Debt
Obligations; 

  

	 	(v)	any defense based upon any statute or rule of law which provides that the obligation of a surety must be neither larger in amount nor in other respects more burdensome than that of the principal; 

 

	 	(vi)	any defense based upon any Secured Party’s errors or omissions in the administration of the Senior Debt Obligations, except behavior which amounts to fraud, gross negligence or bad faith; 

 

	 	(vii)	(A) any principles or provisions of law, statutory or otherwise, which are or might be in conflict with the terms hereof and any legal or equitable discharge of such Guarantor’s obligations hereunder, (B) the
benefit of any statute of limitations affecting such Guarantor’s liability hereunder or the enforcement hereof, and (C) promptness, diligence and any requirement that any Secured Party protect, secure, perfect or insure any security
interest or lien or any property subject thereto; 

  

	 	(viii)	notices, demands, presentments, protests, notices of protest, notices of dishonor and notices of any action or inaction, including acceptance hereof, notices of default hereunder, under any Finance Documents or any
agreement or instrument related thereto, notices of any renewal, extension or modification of the Senior Debt Obligations or any agreement related thereto, notices of any extension of credit to the Company and notices of any of the matters referred
to in clause (c) below and any right to consent to any thereof; and 

  
 -140- 

 § 11.6(a)(viii) 

 

	 	(ix)	any defenses or benefits that may be derived from or afforded by law which limit the liability of or exonerate guarantors or sureties, or which may conflict with the terms hereof. 

 

	 	(b)	Each Guarantor understands and agrees that the guarantee contained in this Article 11 (Guarantees) shall be construed as a continuing, absolute and unconditional guarantee of payment without regard to:

  

	 	(i)	the validity or enforceability of this Agreement or any other Finance Document, any of such Senior Debt Obligations or any other collateral security therefor or guarantee or right of offset with respect thereto at any
time or from time to time held by any Secured Party; 

  

	 	(ii)	any defense, set-off, recoupment or counterclaim (other than a defense of payment or performance) which may at any time be available to or be asserted by the Company or any other
Person against any Secured Party; or 

  

	 	(iii)	any other circumstance whatsoever (with or without notice to or Knowledge of the Company or such Guarantor) which constitutes, or might be construed to constitute, an equitable or legal discharge of the Company for such
Senior Debt Obligations, or of such Guarantor under the guarantee contained in this Article 11 (Guarantees), in a Bankruptcy Proceeding or in any other instance. 

 

	 	(c)	The obligations of each Guarantor hereunder are independent of the obligations of the Company and the obligations of any other guarantor (including any other Guarantor) and a separate action or actions may be brought
and prosecuted against such Guarantor, whether or not any action is brought against the Company or any of such other guarantors and whether or not the Company is joined in any such action or actions. When making any demand hereunder or otherwise
pursuing its rights and remedies hereunder against any Guarantor, the Security Trustee may, but shall be under no obligation to, make a similar demand on or otherwise pursue such rights and remedies as it may have against any of the Securing Parties
or any other Person or against any collateral security or guarantee for such Senior Debt Obligations or any right of offset with respect thereto, and any failure by the Security Trustee or any other Secured Party to make any such demand, to pursue
such other rights or remedies or to collect any payments from any other Securing Party or any other Person or to realize upon any such collateral security or guarantee or to exercise any such right of offset, or any release of any other Securing
Party or any other Person or any such collateral security, guarantee or right of offset, shall not relieve any Guarantor of any obligation or liability hereunder, and shall not impair or affect the rights and remedies, whether express, implied or
available as a matter of law, of any Secured Party against any Guarantor. For the purposes hereof “demand” shall include the commencement and continuance of any legal proceedings. 

  
 -141- 

 § 11.6(c) 

 

	 	(d)	In furtherance of the foregoing and without limiting the generality thereof, each Guarantor agrees as follows: 

  

	 	(i)	The Security Trustee may enforce this guarantee upon the occurrence of a Declared Event of Default notwithstanding the existence of any dispute between the Company and any Secured Party with respect to the existence of
such Declared Event of Default; and 

  

	 	(ii)	The Security Trustee, on instructions of the Secured Parties as provided herein, upon such terms as it deems appropriate, without notice or demand and without affecting the validity or enforceability hereof or giving
rise to any reduction, limitation, impairment, discharge or termination of any Guarantor’s liability hereunder, from time to time may (A) subject to the provisions of this Agreement and the other Finance Documents, enforce and apply any
Security Interest now or hereafter held by or for the benefit of the Secured Party in respect hereof or the Senior Debt Obligations and direct the order or manner of sale thereof, or exercise any other right or remedy that such Secured Party may
have against any such Security Interest, in each case as such Secured Party in its discretion may determine consistent herewith and any applicable security agreement, including foreclosure on any such Security Interest pursuant to one or more
judicial or nonjudicial sales, whether or not every aspect of any such sale is commercially reasonable, and even though such action operates to impair or extinguish any right of reimbursement or subrogation or other right or remedy of any Guarantor
against any other Securing Party or any Security Interest for the Senior Debt Obligations; and (B) exercise any other rights available to it under the Finance Documents. 

 

	 	11.7	Authority of Guarantors or Company 

 It is not necessary for any Secured Party to inquire
into the capacity or powers of any Guarantor of the Company or the officers, directors or any agents acting or purporting to act on behalf of any of them. 
  

	 	11.8	Bankruptcy 

  

	 	(a)	 So long as any Senior Debt Obligations remain outstanding, no Guarantor shall, without the prior written consent
of the Security Trustee acting pursuant to the instructions of Requisite Secured Parties, commence or join with any other Person in commencing any Bankruptcy Proceeding of or against the Company or any other Guarantor. Notwithstanding the foregoing,
in any Bankruptcy Proceeding the Guarantors may file a proof of claim or statement of interest with respect to the Senior Debt Obligations. The obligations of the Guarantors hereunder shall not be reduced, limited, impaired, discharged, terminated
or, subject to the 

  
 -142- 

 § 11.8(a) 

 

	 	
applicability of a stay in connection with a Bankruptcy Proceeding, deferred or suspended by any Bankruptcy of any other Securing Party or by any defense which any other Securing Party may have
by reason of the order, decree or decision of any court or administrative body resulting from any Bankruptcy Proceeding. 

  

	 	(b)	Each Guarantor acknowledges and agrees that any interest on any portion of the Senior Debt Obligations which accrues after the commencement of any Bankruptcy of any Securing Party (or, if interest on any portion of such
Senior Debt Obligations ceases to accrue by operation of law by reason of the commencement of such Bankruptcy Proceeding, such interest as would have accrued on such portion of such Senior Debt Obligations if such Bankruptcy Proceeding had not been
commenced) shall be included in such Senior Debt Obligations. The Guarantors will permit any trustee in bankruptcy, receiver, debtor in possession, assignee for the benefit of creditors or similar Person to pay the Security Trustee or any other
Secured Party, or allow the claim of the Security Trustee or any other Secured Party in respect of, any such interest accruing after the date on which such Bankruptcy Proceeding is commenced. 

 

	 	(c)	If acceleration of the time for payment of any amount payable by the Company under this Agreement or any other Finance Document is stayed upon the Bankruptcy of the Company, all such amounts otherwise subject to
acceleration under the terms of this Agreement or any other Finance Document shall nonetheless be payable by each of the Guarantors hereunder forthwith on demand by the Security Trustee subject to the applicability of any stay in connection with a
Bankruptcy Proceeding. 

  

	 	11.9	Release 

  

	 	(a)	Notwithstanding anything to the contrary contained herein or in any other Finance Document, the guarantees in this Article 11 (Guarantees) are automatically released on the Discharge Date in respect of all Senior
Debt Obligations and the Security Trustee is hereby irrevocably authorized by each Secured Party (without requirement of notice to or consent of any Secured Party except as expressly required by this Agreement) to take any action requested by the
Company having the effect of releasing any guarantee of a Guarantor to the extent necessary to permit consummation of any transaction not prohibited by any Finance Document or that has been consented to in accordance with Section 7.2(c)
(Modification Approval Levels – Release of Collateral, Security Interests or Guarantees). 

  

	 	(b)	If all of the Guarantor Interests of any Guarantor or any of its successors in interest hereunder shall be sold or otherwise disposed of (including by merger or consolidation) in accordance with the terms and conditions
hereof, then the guarantee of such Guarantor or such successor in interest, as the case may be, hereunder shall automatically be discharged and released without any further action by any other Person effective as of the time of such asset sale.

  
 -143- 

 § 11.12 
  

	 	11.10	Reinstatement 

 Each Guarantor agrees that the guarantee contained in this Article 11
(Guarantees) shall continue to be effective, or be reinstated, as the case may be, if at any time any payment, or any part thereof, of any of the Senior Debt Obligations is rescinded or must otherwise be restored or returned by any Secured
Party upon the Bankruptcy of any Securing Party or in any of the circumstances described in Section 10.1(a) (Nature of Obligations), all as though such payments had not been made. 

 

	 	11.11	Information 

 Each Guarantor assumes all responsibility for being and keeping itself
informed of the other Securing Parties’ financial condition and assets and of all other circumstances bearing upon the risk of nonpayment of the Senior Debt Obligations and the nature, scope and extent of the risks that such Guarantor assumes
and incurs hereunder, and agrees that no Secured Party will have any duty to advise such Guarantor of information known to it or any of them regarding such circumstances or risks or to disclose or discuss with any Guarantor its assessment, or any
Guarantor’s assessment, of the financial condition of the Company. Any Advance may be made to the Company or continued from time to time, and any Permitted Senior Debt Hedging Instruments may be entered into from time to time, in each- case
without notice to or authorization from any Guarantor regardless of the financial or other condition of the Company at the time of any such grant, continuation or Advance, or at the time such Permitted Senior Debt Hedging Instrument is entered into,
as the case-may be. Each Guarantor has adequate means to obtain information from the Company on a continuing basis concerning the financial condition of the Company and its ability to perform its obligations
under the Finance Documents, and each Guarantor assumes the responsibility for being and keeping informed of the financial condition of the Company and of all circumstances bearing upon the risk of nonpayment of the Senior Debt Obligations. Each
Guarantor hereby waives and relinquishes any duty on the part of any Secured Party to disclose any matter, fact or thing relating to the business, operations or conditions of the Company now known or hereafter known by any Secured Party. 

 

	 	11.12	Instrument for Payment of Money 

 Each Guarantor hereby acknowledges that the guarantee
in this Article 11 (Guarantees) constitutes an instrument for the payment of money, and consents and agrees that the Security Trustee, on behalf of the Secured Parties, at its sole option, in the event of a dispute by such Guarantor in the
payment of any moneys due hereunder, shall have the right to bring a motion-action under New York CPLR Section 3213. 
  

	 	11.13	Limitation on Guarantee Obligations 

 In any action or proceeding involving any state
corporate, limited partnership or limited liability company law, or any applicable state, federal or foreign bankruptcy, insolvency, reorganization or other law affecting the rights of creditors generally, if the obligations of any Guarantor
hereunder and under the other Finance Documents would otherwise be 

  
 -144- 

 § 11.14(b) 

 

 
held or determined to be void, voidable, invalid or unenforceable or subordinated to the claims of any other creditors, on account of the amount of its liability hereunder or under any of the
other Finance Documents), then, notwithstanding any other provision to the contrary, the amount of such liability shall, without any further action by such Guarantor, any other Securing Party or any other Person, be automatically limited and reduced
to the highest amount (after giving effect to the right of contribution established in Section 11.2 (Right of Contribution)) that is valid and enforceable and not subordinated to the claims of other creditors as determined in such action
or proceeding. 
  

	 	11.14	Swap Obligations 

  

	 	(a)	Excluded Swap Obligations. Notwithstanding anything to the contrary in this Agreement, but after taking into account clause (b) below, no Securing Party shall be obligated to provide a guarantee or grant
security in respect of an Excluded Swap Obligation. 

  

	 	(b)	Keepwell. Each Qualified ECP Party hereby jointly and severally absolutely, unconditionally and irrevocably undertakes to provide such funds or other support as may be needed from time to time by each other
Securing Party to honor all of its obligations under this Agreement and otherwise under the Finance Documents in respect of Swap Obligations; provided, however, that each Qualified ECP Party shall only be liable under this clause
(b) for the maximum amount of such liability that can be hereby incurred without rendering its obligations under this clause (b), or otherwise under this Agreement and otherwise under the Finance Documents, voidable under applicable law
relating to fraudulent conveyance or fraudulent transfer, and not for any greater amount. The obligations of each Qualified ECP Party under this clause (b) shall remain in full force and effect until the Discharge Date. Each Qualified ECP Party
intends that this clause (b) constitute, and this clause (b) shall be deemed to constitute, a “keepwell, support, or other agreement” for the benefit of each other Securing Party for all purposes of Section 1a(18)(A)(v)(II)
of the Commodity Exchange Act. 

  

	 	11.15	Additional Guarantors 

 If at any time, the Company is required under any
Senior Debt Instrument to cause any Subsidiary acquired or created by the Company to become a guarantor of any Senior Debt, the Company shall cause such Subsidiary to accede to this Agreement as a guarantor hereunder and guarantee all the Senior
Debt Obligations in accordance with, and pursuant to, Section 11 (Guarantees) of this Agreement. Upon its accession to this Agreement, such subsidiary shall be deemed to be a “Guarantor” hereunder. Any accession agreement
entered into pursuant to this Section 11.15 (Additional Guarantors) shall be in form and substance reasonably satisfactory to the Security Trustee. 

  
 -145- 

 § 12 
  

	12.	MISCELLANEOUS 

  

	 	12.1	Termination 

  

	 	(a)	Subject to reinstatement as provided in Section 10.1 (Nature of Obligations), upon delivery by each Senior Creditor Group Representative to the Security Trustee of the certificate required under
Section 2.9 (Discharge of Certain Senior Debt Obligations) hereunder stating that the Discharge Date with respect to all of the Senior Debt Obligations shall have occurred, this Agreement and the Security Interests and rights created by
or pursuant to this Agreement, any Security Document or any Direct Agreement shall automatically terminate (to the extent permitted by applicable law), and the Senior Creditors and their respective attorneys-in-fact shall, at the expense of the Securing Parties, promptly execute and deliver a termination statement, pay-off letter and such instruments of
satisfaction, discharge and release of security in respect of all Collateral as may be reasonably requested by the Company or Holdco, the Security Trustee shall deliver to Holdco any Guarantor Interests and any other securities held by it, and the
Account Bank shall (upon receipt of written instruction (which may be a payoff letter or other instrument of satisfaction, discharge or release of the Collateral) from the Security Trustee) assign, transfer and deliver to or to the order of the
Company all funds and investments in the Accounts. 

  

	 	(b)	Subject to reinstatement as provided in Section 10.1 (Nature of Obligations), if any Senior Debt Obligations shall be discharged as provided in clause (a) above, the former Holders (and their respective
Senior Creditor Group Representatives) shall no longer have any rights hereunder save for the provisions which by their terms expressly continue. 

  

	 	12.2	Waiver of Immunity 

 To the extent that any party hereto has or hereafter may acquire, or
be entitled to claim for itself or its assets, any immunity from jurisdiction of any court or from any legal process (whether through service or notice, attachment in aid of execution, execution or otherwise) with respect to itself or its assets, it
hereby irrevocably agrees not to claim and hereby irrevocably waives such immunity in respect of its obligations under the Finance Documents to which it is a party and all other documents to be executed and delivered in connection with the Finance
Documents to which it is a party and the transactions contemplated thereby and, without limiting the generality of the foregoing, hereby agrees that the waivers set forth in this Section 12.2 (Waiver of Immunity) shall be effective to
the fullest extent permitted under applicable law. 
  

	 	12.3	Judgment Currency 

 In respect of any judgment or order given or made for any amount due
under this Agreement or any other Finance Document that is expressed and paid in a currency (the “Judgment Currency”) other than US Dollars, the Securing Parties shall indemnify each Secured Party against any loss incurred by it as
a result of any variation as between 

  
 -146- 

 § 12.4 
  

 
(a) the rate of exchange at which the US Dollar amount is converted into the Judgment Currency for the purpose of such judgment or order and (b) the rate of exchange on the
Business Day following receipt by such Secured Party of any sum adjudged to be due under the Finance Documents, as quoted by the Security Trustee or by a known dealer in the Judgment Currency that is designated by the Security Trustee, at which such
Secured Party is able to purchase US Dollars with the amount of the Judgment Currency actually received by such Secured Party. The foregoing indemnity shall constitute a separate and independent obligation of the Securing Parties and shall survive
any termination of this Agreement and the other Finance Documents, and shall continue in full force and effect notwithstanding any such judgment or order as aforesaid. The term “rate of exchange” shall include any premiums and costs of
exchange payable in connection with the purchase of or conversion into US Dollars. 
  

	 	12.4	Severability 

 Any term or provision of this Agreement or the application thereof to any
circumstance that is illegal, invalid, prohibited or unenforceable (to any extent) in any jurisdiction shall, as to such jurisdiction, be ineffective to the extent of such illegality, invalidity, prohibition or unenforceability, without invalidating
or rendering unenforceable the remaining terms or provisions hereof or the application of such term or provision to circumstances other than those to which it is held illegal, invalid, prohibited or unenforceable. Any such illegality, invalidity,
prohibition or unenforceability in any jurisdiction shall not invalidate or render unenforceable such term or provision in any other jurisdiction and the parties hereto shall enter into good faith negotiations to replace the invalid, illegal,
prohibited, or unenforceable term or provision with a view to obtaining the same commercial effect as this Agreement would have had if such term or provision had been legal, valid, and enforceable. To the extent permitted by applicable laws, the
parties hereto waive any provision of law that renders any term or provision of this Agreement illegal, invalid, prohibited or unenforceable in any respect. 
  

	 	12.5	Entire Agreement 

 This Agreement (including Schedules), the Security Documents and the
other Finance Documents (together with any other agreements or documents referred to or incorporated by reference therein) constitute the entire agreement and understanding, and supersede all prior agreements and understandings (both written and
oral), between or among any of the parties hereto relating to the transactions contemplated hereby or thereby. 
  

	 	12.6	Confidentiality 

  

	 	(a)	Each of the Secured Parties agrees to maintain the confidentiality of the Confidential Information and all information disclosed to it concerning this Agreement and the other Finance Documents, except that the
Confidential Information and such other information disclosed to a Secured Party may be disclosed: 

  
 -147- 

 § 12.6(a)(iii) 

 

	 	(i)	to its Related Parties, including accountants, legal counsel and other advisers, on a need-to-know basis; 

 

	 	(ii)	to any insurer or guarantor of Senior Debt Obligations; 

  

	 	(iii)	to any rating agency in connection with the rating of a Secured Party or Securing Party; 

  

	 	(iv)	to the extent requested or required by any governmental agency, court, regulatory body or other supervisory authority having jurisdiction over such party; provided that: 

 

	 	(A)	in the reasonable opinion of such party, such agency, court or other authority has the authority to request or require such disclosure; 

 

	 	(B)	such disclosure is made in accordance with such agency’s, court’s or other authority’s request and is kept to the minimum necessary (in the reasonable judgment of such party and its counsel) for the
purpose for which it is made and, to the extent practicable, made subject to an appropriate protective order; and 

  

	 	(C)	other than with respect to disclosures made to (I) the Federal Reserve or any other central bank in connection with a pledge by such party of Loans in favor of the Federal Reserve or such central bank and
(II) disclosures made to regulatory authorities in the course of routine supervisory audits or reviews, such party shall, subject to legal and regulatory restrictions, have given, as soon as reasonably practicable after receiving such a
request, written notice to the party or parties to whom the information relates prior to such disclosure and received its or their views in relation to such requested disclosures to the extent such views are received within the time period that it
has to make the requested disclosure; 

  

	 	(v)	to the extent required by applicable laws or regulations; 

  

	 	(vi)	to any other party hereto; 

  

	 	(vii)	in connection with the exercise of any duties or remedies under any of the Finance Documents or any suit, action or proceeding relating to the Finance Documents or the enforcement of rights under any of the Finance
Documents; 

  

	 	(viii)	subject to the execution of an agreement containing provisions substantially the same as those of this Section 12.6 (Confidentiality), to any permitted assignee or transferee of, or permitted sub-participant in, or any prospective permitted assignee or transferee or permitted sub-participant in, any of its rights or obligations under this Agreement or any other
Finance Document or to any Person with whom such Senior Creditor enters into or reasonably expects to enter into a merger, amalgamation, acquisition or similar arrangement; 

  
 -148- 

 § 12.6(a)(x) 

 

	 	(ix)	with the written consent of the Company; 

  

	 	(x)	to the extent such Confidential Information or such other information referred to in this Section 12.6 (Confidentiality): 

 

	 	(A)	becomes publicly available other than as a result of a breach of the obligations contained in this Section 12.6 (Confidentiality); or 

 

	 	(B)	becomes available to a party on a non-confidential basis from a source other than any other party or an Affiliate thereof; or 

 

	 	(xi)	in the case of any information disclosed to it in connection with “know your customer” or other similar checks: 

  

	 	(A)	if required under a binding order of a Governmental Authority or any procedure for discovery in any proceedings; or 

  

	 	(B)	if required under any law or any administrative or regulatory guideline, directive, request or policy, whether or not having the force of law, and, if not having the force of law, with which responsible bankers or
financial institutions similarly situated normally would comply. 

  

	 	(b)	Any Persons to whom disclosure is made in accordance with this Section 12.6 (Confidentiality) (other than sub-clause (a)(x) above) shall be informed of the
confidential nature of that Confidential Information or such other information referred to in this Section 12.6 (Confidentiality) and, other than for disclosure made pursuant to sub-clauses
(a)(iii), (iv), (v), (vi), (vii) or (xi) above, instructed to keep all such information confidential. 

  

	 	(c)	 Additionally, disclosure of any confidential document that contains confidentiality restrictions that require any
Securing Party, or the Sponsor or any of their Affiliates, as applicable, to comply with a restricted procedure and LNG SPAs containing commercially sensitive information and identified as such by the Borrower to the Security Trustee (each such
document, along with those documents listed in Schedule M (Restricted Documents), a “Restricted Document”) shall only be permitted subject to compliance with the procedures in this clause (c). Restricted Documents may be
disclosed to the Intercreditor Agent and the applicable Consultant or legal advisor (to the extent required by such Consultant or legal advisor in order to deliver reports required pursuant to any Finance Document) only (subject, in the case that
such Restricted Document contains pricing and/or technical information, to the Intercreditor Agent and the applicable Consultant or legal advisor complying with procedures related to such disclosure agreed with the Securing Parties and, if
requested, the counterparty to such Restricted Document, which procedures may 

  
 -149- 

 § 12.7(a)(ii) 

 

 
require disclosing such Restricted Document only to the common legal counsel of the relevant Finance Parties and not directly to the Intercreditor Agent or such Consultant) and may redact the
specific pricing information and/or technical information (in the case of technical information (but not pricing information), to the extent that such technical information is subject to a confidentiality obligation that prevents the Securing
Parties or the Sponsor or their Affiliates, as applicable, from providing it to any Finance Party) from any other copies thereof to be provided to any other Finance Party unless such other Finance Party also agrees to comply with confidentiality
arrangements that may be required by the counterparty to such Restricted Document. 
  

	 	12.7	Notices 

  

	 	(a)	Except in the case of notices and other communications expressly permitted to be given by telephone (which shall be in English language), all notices and other communications provided for herein shall be in writing in
the English language (or, if not available in the English language, accompanied by an English language translation of such document) and shall be delivered by hand or overnight courier service, mailed by certified or registered mail or sent by
facsimile transmission with return receipt or by email to the address, facsimile number and/or email address of the party to whom notice is being sent set forth below: 

 

	 	(i)	with respect to the Securing Parties and Holdco, the corresponding address and other notice information set forth in Schedule B (Addresses for Notices of the Securing Parties and Holdco); 

 

	 	(ii)	with respect to each Senior Creditor (excluding any Holders of notes or other securities issued pursuant to an Indenture) and Senior Creditor Group Representative, to the corresponding address and other notice
information set forth in Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility
Lenders Facility Office); 

  

	 	(iii)	with respect to the Intercreditor Agent, to: 

 Société Générale

 245 Park Avenue 
 New York,
NY 10167 
 Attention: Ellen Turkel 

Telephone: (212) 278-6437 

Fax: (212) 278-6136 

Email: ellen.turkel@sgcib.com 

  
 -150- 

 § 12.7(a)(v) 

 

 with a copy to: 

245 Park Avenue 
 New York, NY
10167 
 Attention: Ed Grimm 

Telephone: (212) 278-6450 

Fax: (212) 278-6136 

Email: edward.grimm@sgcib.com 
  

	 	(iv)	with respect to the Account Bank, to: 

 Mizuho Bank, Ltd. 

1251 Avenue of the Americas 

New York, NY 10020 
 Attention:
Project Finance 
 Telephone: 212-282-4869 / 212-282-3552 
 Fax: 212-282-3618 
 Email: stephen.hughes@mizuhocbus.com; 

hiroe.nikaido@mizuhocbus.com; 

and 
  

	 	(v)	with respect to the Security Trustee, to: 

 Société Générale 

245 Park Avenue 
 New York, NY
10167 
 Attention: Ellen Turkel 

Telephone: (212) 278-6437 

Fax: (212) 278-6136 

Email: ellen.turkel@sgcib.com 

with a copy to: 
 245 Park
Avenue 
 New York, NY 10167 

Attention: Ed Grimm 
 Telephone:
(212) 278-6450 
 Fax: (212) 278-6136 

Email: edward.grimm@sgcib.com 
  

	 	(b)	Any notice, demand, consent or approval or communication given electronically by the Security Trustee in connection with a Finance Document may be given to any Secured Party that has expressly agreed that it will accept
communication of information by this method by means of the “Debt Domain Website” established by the Security Trustee and the Intercreditor Agent (the “Debt Domain Website”), access to which is restricted to the parties to
the Finance Documents, or by other electronic means in a manner and subject to rules established by the Security Trustee and the Intercreditor Agent and agreed with the Company; provided that the Intercreditor Agent may set access protocols
as reasonably needed to communicate confidentially with the other Secured Parties at its sole discretion. 

  
 -151- 

 § 12.7(c) 

 

	 	(c)	Any party may change its address, fax number or email address for notices and other communications hereunder by notice to the other parties. All notices and other communications given to any party in accordance with the
provisions of this Agreement shall be deemed to have been received: (i) in the case of a letter, when delivered personally or five days after it has been put into the post; (ii) in the case of a fax, when a complete and legible copy is
received by the addressee; (iii) in the case of email, upon receipt by the sender of a return receipt message (provided that, in the case of sub-clauses (ii) and (iii) above, if the date
of dispatch is not a Business Day or the time of dispatch is after 17:00 in the location of dispatch, it shall be deemed to have been received at the opening of business on the next Business Day); and (iv) in the case of a notice contemplated
by clause (b) above, on the later of (x) a notice being posted on the Debt Domain Website and (y) receipt by the Security Trustee of a return receipt message in respect of an email the Security Trustee has sent to the relevant
party’s email address (as notified to the Security Trustee in writing at least five days before any email is sent by the Security Trustee or notice posted on the Debt Domain Website) notifying that the notice has become available on the Debt
Domain Website. 

  

	 	(d)	Communication by one party to any other party may, at the election of each such party, be by electronic mail. For the purpose of the Finance Documents, an electronic communication shall be treated as being in writing.
Inclusion of an email address or addresses in the notice details for a party shall indicate that such party elects to receive and send communications by email subject to any particular requirements relating thereto of which it has notified each
other party. The absence of the notification of an email address shall indicate that such party does not elect to receive or send communication by email, and any email communication to it shall be deemed not to have been delivered.

  

	 	(e)	Each of the Securing Parties and the other parties to this Agreement: 

  

	 	(i)	consents to the inclusion in the Debt Domain Website of its name, its logo and a link to its website, if any; 

  

	 	(ii)	acknowledges that the Security Trustee will issue Access Information to the Collateral Parties and the other parties to this Agreement; 

 

	 	(iii)	undertakes to ensure that all Access Information issued to it by the Security Trustee is kept secure and confidential in accordance with Section 12.6 (Confidentiality); 

 

	 	(iv)	acknowledges that the Debt Domain Website is provided “as is” and “as available” and that the Security Trustee does not warrant the accuracy or completeness of communications provided through the
Debt Domain Website or the adequacy of the Debt Domain Website and expressly disclaims liability for errors or omissions in communications provided through the Debt Domain Website; 

  
 -152- 

 § 12.8 
  

	 	(v)	acknowledges that no warranty of any kind, express implied or statutory, including any warranty of merchantability, fitness for a specific purpose, non-infringement of third party
rights or freedom from viruses or other code defects, is made by the Security Trustee in connection with communications provided through the Debt Domain Website or the Debt Domain Website; and 

 

	 	(vi)	agrees that neither the Security Trustee nor any of its officers, directors, employees, agents, advisors or representatives is liable for damages of any kind, including direct or indirect, special, incidental or
consequential, or any losses or expenses (whether in tort, contract or otherwise) incurred or suffered by it or any other Person as a result of its access or use of the Debt Domain Website or inability to access or use the Debt Domain Website, other
than in the case of the gross negligence, fraud, or willful misconduct of the Security Trustee as determined by a court of competent jurisdiction in a final non-appealable judgment. 

 

	 	12.8	Successors and Assigns; Benefits of Agreement 

  

	 	(a)	This Agreement shall be binding upon and inure to the benefit of each of the Parties hereto and their subsequent respective successors, permitted transferees and permitted assigns, and nothing in this Agreement, in any
Senior Debt Instrument, in any Permitted Senior Debt Hedging Instrument, or in any other Finance Document, express or implied, shall give to any other Person (other than any Collateral Party or Secured Parties claiming through the parties hereto to
the extent expressly contemplated hereby) any benefit or any legal or equitable right or remedy under this Agreement. 

  

	 	12.9	Remedies 

  

	 	(a)	Other than as stated expressly herein or therein, no remedy under this Agreement or any other Finance Document conferred upon the Secured Parties is intended to be exclusive of any other remedy and each and every such
remedy shall be cumulative and shall be in addition to every other remedy given hereunder, under the Security Documents or under any other Finance Document, or now or hereafter existing at law or in equity or by statute or otherwise.

  

	 	(b)	 Subject to Section 6.3 (Conduct of Security Enforcement Action), the amounts payable by the Securing
Parties at any time under a Senior Debt Instrument or a Permitted Senior Debt Hedging Instrument shall each be a separate and independent debt and each Senior Creditor, except as otherwise specifically provided in this Agreement or any other Finance
Document, shall be entitled to protect and enforce its rights arising out of this Agreement, its Senior Debt Instrument or a Permitted Senior Debt Hedging Instrument, the Security 

  
 -153- 

 § 12.9(d) 

 

	 	
Documents or any other Finance Document, and its right, pursuant to such Senior Debt Instrument or a Permitted Senior Debt Hedging Instrument, to cancel or suspend its commitment to provide
Senior Debt Obligations and to accelerate the maturity of amounts due under its Senior Debt Instrument or a Permitted Senior Debt Hedging Instrument, and, except as aforesaid, it shall not be necessary for any other Senior Creditor to consent to, or
be joined as an additional party in, any proceedings for such purposes. 

  

	 	(c)	Except as otherwise specifically provided in this Agreement or any other Finance Document, no failure on the part of any Secured Party to exercise and no delay in exercising, and no course of dealing with respect to,
any right, power, or privilege under this Agreement or any other Finance Document shall operate as a waiver thereof nor shall any single or partial exercise of any right, power or privilege under any such document preclude any other or further
exercise thereof or the exercise of any other right, power or privilege. Neither the Security Trustee nor any Secured Party shall be responsible for the failure of any other Secured Party to perform its obligations hereunder or under any Finance
Document. 

  

	 	(d)	In case any Secured Party or the Security Trustee on behalf of or for the benefit of the Senior Creditors shall have proceeded to enforce any right, remedy or power under and in accordance with this Agreement or any
other Finance Document and the proceeding for the enforcement thereof shall have been discontinued or abandoned for any reason or shall have been determined adversely to such Secured Party, then and in every such case the Securing Parties and the
Secured Party shall, subject to any effect of or determination in such proceeding, severally and respectively be restored to their former positions and rights hereunder and under the other Finance Documents, and thereafter all rights, remedies and
powers of the Senior Creditors shall continue as though no such proceeding had been taken. 

  

	 	(e)	The rights of each Secured Party (i) may be exercised as often as necessary, (ii) are cumulative and not exclusive of its rights under general law, and (iii) may be waived only in writing and
specifically. 

  

	 	12.10	Execution in Counterparts 

 This Agreement may be executed in any number of counterparts
and by the different parties hereto on separate counterparts, each of which when so executed and delivered shall be an original, but all the counterparts shall together constitute one and the same instrument. Delivery of an executed counterpart of a
signature page of this Agreement by facsimile or in electronic format (i.e., “pdf” or “tif”) shall be as effective as delivery of a manually executed counterpart of this Agreement. 

 

	 	12.11	GOVERNING LAW 

 THIS AGREEMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE
LAWS OF THE STATE OF NEW YORK, UNITED STATES OF AMERICA WITHOUT REGARD TO CONFLICTS OF LAWS PRINCIPLES THEREOF THAT WOULD RESULT IN THE APPLICATION OF THE LAWS OF ANY OTHER JURISDICTION. 

  
 -154- 

 § 12.13(a) 

 

	 	12.12	WAIVER OF JURY TRIAL 

 EACH PARTY HERETO HEREBY WAIVES, TO THE FULLEST EXTENT PERMITTED
BY APPLICABLE LAW, ANY AND ALL RIGHT TO TRIAL BY JURY IN ANY LEGAL PROCEEDING ARISING OUT OF OR RELATING TO THIS AGREEMENT, THE FINANCE DOCUMENTS OR THE TRANSACTIONS CONTEMPLATED THEREBY. 

 

	 	12.13	Consent to Jurisdiction 

  

	 	(a)	The parties to this Agreement (and the Senior Creditor Group Representatives on behalf of their respective Senior Creditors) consent to the non-exclusive jurisdiction of the
courts of the State of New York (except as otherwise specifically provided herein). 

  

	 	(b)	Each party hereto: 

  

	 	(i)	hereby irrevocably consents and agrees for the benefit of the Secured Parties that the federal or state courts in the Borough of Manhattan, The City of New York in the State of New York shall have jurisdiction over any
legal action, suit or proceeding against it with respect to its obligations, liabilities or any other matter under or arising out of or in connection with this Agreement and any other Finance Documents; 

 

	 	(ii)	irrevocably waives any objection it may now or hereafter have to the laying of venue of any action or proceeding in any such court and any claim it may now or hereafter have that any action or proceeding has been
brought in an inconvenient forum; and 

  

	 	(iii)	irrevocably consents and agrees that the submission to the jurisdiction of the federal or state courts in the Borough of Manhattan, The City of New York in the State of New York shall not limit the rights of the Senior
Creditor Group Representatives (on behalf of the Senior Creditors) to bring any action or proceeding in any other court of competent jurisdiction nor shall the bringing of any action or the taking of any proceedings in any other jurisdiction
(whether concurrently or not) limit such rights, in each case, to the extent permitted by applicable law. 

  

	 	(c)	Without prejudice to any other mode of service allowed under any relevant law, each Securing Party: 

  

	 	(i)	agrees that failure by a process agent to notify it of the process will not invalidate the proceedings concerned; 

  
 -155- 

 § 12.13(d) 

 

	 	(ii)	shall maintain a duly appointed and authorized agent for service of process in relation to any proceedings before the federal or state courts in the Borough of Manhattan, The City of New York in the State of New York in
connection with this Agreement and shall keep the Security Trustee advised of the identity and location of such agent and acknowledge that the Securing Parties shall appoint Corporation Service Company at its registered office (being, on the date of
this Agreement, at 1180 Avenue of the Americas, Suite 210, New York, NY 10036); 

  

	 	(iii)	hereby irrevocably authorizes the Security Trustee to appoint an agent for service of process on its behalf should it at any time fail to maintain in full force and effect a process agent in accordance with this
Section 12.13 (Consent to Jurisdiction), and the Security Trustee shall promptly notify it of any such appointment; and 

  

	 	(iv)	agrees that service of process in respect of it upon such agent, together with notice of such service given to it in the manner provided in Section 12.7 (Notices) shall be deemed to be effective service of
process upon it in any such proceeding. 

  

	 	(d)	Each of the parties agrees that upon service of process to a Securing Party’s agent for service of process appointed for such purpose under clause (c) above, a copy of such process shall be delivered to such
Securing Party with the procedure for notices set forth in Section 12.7 (Notices); provided that the non-delivery of such copy will not affect the enforceability of such process validly
served upon such agent. 

  

	 	12.14	Amendments 

  

	 	(a)	Except with regard to any waivers as expressly provided in this Agreement, this Agreement may be Modified by an agreement in writing signed by the Security Trustee, based on the instructions described in
Section 7.2(a) (Modification Approval Levels – Modifications to this Agreement) and each Securing Party; provided this Agreement may not be Modified in a manner adverse to, or that would otherwise impact the rights or
obligations of, the Account Bank or the Security Trustee, in each case in their capacity as such, without the consent of the Account Bank or the Security Trustee, as applicable. 

 

	 	(b)	 The agreement contemplated in clause (a) above shall not be required for (i) a successor Security
Trustee to accede to this Agreement in accordance with Section 8.7(f) (Resignation, Removal and Replacement of Security Trustee), for a successor Account Bank to accede to this Agreement in accordance with Section 9.9(e)
(Resignation, Removal and Replacement of the Account Bank); (ii) a successor Intercreditor Agent to accede to this Agreement; (iii) the Security Trustee to make entries on (1) Schedule B (Addresses for Notices of the
Securing Parties and Holdco) pursuant to a transfer permitted by the Finance Documents and (2) Schedule C (List of Senior Creditors, Senior Creditor Group  

  
 -156- 

 § 12.16 
  

	 	
Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office)
pursuant to Section 2.7 (Accession of Senior Creditor Group Representatives); or (iv) the Securing Parties to make entries on or updates to (A) Schedule E (Commercial Tort Claims) pursuant to Section 3.5(g)(v)
(Perfection and Maintenance of Security Interests – Intellectual Property Recording Requirements) and on Schedule J (Intellectual Property) pursuant to Section 3.5(e) (Perfection and Maintenance of Security
Interests), (B) prior to Second Phase Closing, Schedule H (Details of Initial Accounts) or (C) Schedule M (Restricted Documents) pursuant to Section 12.6 (Confidentiality). 

 

	 	12.15	Conflicts 

 In case of any conflict or inconsistency between this Agreement and
(a) any Senior Debt Instrument or a Permitted Senior Debt Hedging Instrument, with respect to the rights and obligations of the parties prior to enforcement and the conditions and terms on which Security Interests may be enforced; or
(b) any Security Document or Direct Agreement, this Agreement shall control. For the avoidance of doubt, no party may take action to enforce any Security Interest except as permitted in this Agreement. 

 

	 	12.16	Further Assurances 

 The Securing Parties shall deliver (and shall procure that the other
Collateral Parties deliver) to the Security Trustee each of the instruments, agreements, documents and opinions as the Security Trustee may reasonably request to perfect and maintain the Security Interests granted hereunder and under any Security
Document. 
  

	 	12.17	Survival of Obligations 

 The provisions of Section 7.4 (Sponsor Voting),
Section 8.5 (Liability), Section 8.8 (Indemnity), Section 8.11 (Stamp and Other Similar Taxes), Section 9.7 (Exclusion of Liability), Section 9.8 (Indemnities), Section 10.3
(Limitation on Recourse), Section 12.6 (Confidentiality), Section 12.11 (GOVERNING LAW), Section 12.12 (WAIVER OF JURY TRIAL) and Section 12.13 (Consent to Jurisdiction) shall survive the
termination of this Agreement. 
  

	 	12.18	Other Indemnities 

  

	 	(a)	The Securing Parties shall, within ten Business Days of demand, indemnify each Secured Party, and any applicable Related Parties with respect to each such Party (without duplication of any indemnity furnished to any
such parties by any Securing Party under any other Finance Document), against, and hold each such Party harmless from, any claim, cost, loss, expense (including reasonable legal fees and expenses), damage or liability, sustained or incurred by or
asserted against them that arises by reason of their execution and delivery of, performance of their obligations under or participation in the transactions contemplated by any of the Transaction Documents any agreement or instrument contemplated
thereby, including with respect to: 

  
 -157- 

 § 12.18(a)(ii) 

 

	 	(i)	the occurrence of any Loan Facility Event of Default or Unmatured Loan Facility Event of Default; 

  

	 	(ii)	any rescission, reduction, restoration or return of any payment or performance of the Senior Debt Obligations by the Company or any discharge given by a Secured Party (whether in respect of the obligations of the
Company or any security for those obligations or otherwise) as set forth in Section 10.1(a) (Nature of Obligations); 

  

	 	(iii)	the Intercreditor Agent, the Security Trustee or any Facility Agent investigating any event which it reasonably believes is a Loan Facility Event of Default or Unmatured Loan Facility Event of Default; or

  

	 	(iv)	the payment of insurance premia by the Intercreditor Agent or the Security Trustee in accordance with Section 11 (Failure to Maintain Insurance) of Schedule L (Schedule of Minimum Insurance) of the
Common Terms Agreement and any comparable provision in any Senior Debt Instrument then in effect, 

 provided that no
Securing Party shall be liable to any Secured Party or any applicable Related Parties with respect to each such Party under this Section 12.18 (Other Indemnities) to the extent any cost, loss, expense, damage or liability thereon
(A) is incurred as a result of the gross negligence, fraud or willful misconduct of such Person as determined by a final non-appealable judgment of a court of competent jurisdiction or (B) results
from any claims, actions, suits, inquiries, litigations, investigations or proceedings between or among the Secured Parties or other indemnified Persons not arising out of any act or omission of any Securing Party or any of its Affiliates (other
than, in the case of this sub-clause (B), any cost, loss, expense, damage or liability incurred by or asserted against each Facility Agent, the Intercreditor Agent, the Security Trustee or the Account Bank,
which shall remain the liability of the Securing Parties). For the avoidance of doubt, any payment made by a Securing Party under this Section 12.18 (Other Indemnities) shall be subject to any withholding tax gross-up provision applicable to such payment under the related Senior Debt Instrument. 
  

	 	(b)	Notwithstanding anything to the contrary in this Agreement, the indemnification obligations of the Securing Parties in respect of any cost, loss, expense, damage or liability under this Agreement or any other Finance
Document shall not, under any circumstances, be construed to include any loss of profits (but not so as to exclude claims for contractual interest and fees), goodwill, reputation, business opportunity or anticipated saving, or special, indirect,
consequential or punitive damages. 

  
 -158- 

 § 12.19 
  

	 	12.19	Amendment and Restatement 

 This Agreement amends, restates and supersedes the Common
Security and Account Agreement, dated as of May 13, 2015, as amended on September 7, 2017 and February 14, 2018, among the Borrower, the Guarantors, each Initial Senior Creditor Group Representative on its own behalf and on behalf of
the relevant Initial Senior Creditor, the Intercreditor Agent, the Security Trustee and the Account Bank in its entirety. 
 [Signatures
follow] 

  
 -159- 

 IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be duly executed as of the day and year
first above written. 
  

			
	CHENIERE CORPUS CHRISTI HOLDINGS, LLC, as Company
		
	By:	 	/s/ Lisa C. Cohen
	Name:	 	Lisa C. Cohen
	Title:	 	Treasurer

  
 SIGNATURE
PAGE TO COMMON SECURITY AND ACCOUNT AGREEMENT 

 
			
	CORPUS CHRISTI LIQUEFACTION, LLC, as Guarantor
		
	By:	 	/s/ Lisa C. Cohen
	Name:	 	Lisa C. Cohen
	Title:	 	Treasurer

  
 SIGNATURE
PAGE TO COMMON SECURITY AND ACCOUNT AGREEMENT 

 
			
	CHENIERE CORPUS CHRISTI PIPELINE, L.P., as Guarantor
		
	By:	 	/s/ Lisa C. Cohen
	Name:	 	Lisa C. Cohen
	Title:	 	Treasurer

  
 SIGNATURE
PAGE TO COMMON SECURITY AND ACCOUNT AGREEMENT 

 
			
	CORPUS CHRISTI PIPELINE GP, LLC, as Guarantor
		
	By:	 	/s/ Lisa C. Cohen
	Name:	 	Lisa C. Cohen
	Title:	 	Treasurer

  
 SIGNATURE
PAGE TO COMMON SECURITY AND ACCOUNT AGREEMENT 

 
			
	SOCIÉTÉ GÉNÉRALE,
	as Security Trustee
		
	By:	 	/s/ Ellen Turkel
	Name:	 	Ellen Turkel
	Title:	 	Director

  
 SIGNATURE
PAGE TO COMMON SECURITY AND ACCOUNT AGREEMENT 

 
			
	MIZUHO BANK, LTD.,
	as Account Bank
		
	By:	 	/s/ Junji Hasegawa
	Name:	 	Junji Hasegawa
	Title:	 	Managing Director

  
 SIGNATURE
PAGE TO COMMON SECURITY AND ACCOUNT AGREEMENT 

 SCHEDULE A 

COMMON DEFINITIONS AND RULES OF INTERPRETATION 

[See attached.] 

  
 A-1 

 SCHEDULE A 

COMMON DEFINITIONS AND RULES OF INTERPRETATION 
  

	a.	Amendments 

 No amendment to any definition or rule of interpretation in this schedule
shall be effective for purposes of any individual Finance Document unless such amendment has complied with the requirements for amendments to that Finance Document. 
  

	b.	Interpretation 

 In this Agreement and in the Appendices, Exhibits and Schedules hereto,
except to the extent that the context otherwise requires: 
  

	 	i.	the Table of Contents and headings are for convenience only and shall not affect the interpretation of this Agreement; 

  

	 	ii.	unless otherwise specified, references to Articles, Sections, clauses, Appendices, Exhibits and Schedules are references to Articles, Sections and clauses of, and Appendices, Exhibits and Schedules to, this Agreement;

  

	 	iii.	references to any document or agreement shall be deemed to include references to such document or agreement as amended (however fundamentally), supplemented or replaced from time to time in accordance with its terms and
(where applicable) subject to compliance with the requirements set forth herein and therein; provided that with respect to any references to the Equator Principles III, such references shall be deemed to refer to such documents in effect as
of the Second Phase Closing Date, without regard to any amendments, supplements or replacements thereof after such date; 

  

	 	iv.	references to any party to this Agreement or any other document or agreement shall include its successors and permitted transferees and assigns; 

 

	 	v.	an “authorization” includes an authorization, consent, approval, resolution, license, exemption, filing, registration and notarization; 

 

	 	vi.	a “month” is a reference to a period starting on one day in a calendar month and ending on the numerically corresponding day in the next calendar month, except that, if there is no numerically
corresponding day in the month in which that period ends, that period shall end on the last day in that month; 

  

	 	vii.	words importing the plural include the singular and vice versa; 

  
 A-1 

	 	viii.	whenever the context may require, any pronoun shall include the corresponding masculine, feminine and neuter forms; 

  

	 	ix.	the words “include”, “includes” and “including” shall be deemed to be followed by the phrase “without limitation”; 

 

	 	x.	the word “will” shall be construed to have the same meaning and effect as the word “shall”; 

  

	 	xi.	“law” shall be construed as any law (including common or customary law), statute, constitution, decree, judgment, treaty, regulation, directive, by-law, order,
ordinance or any other legislative measure of any government, supranational, local government, statutory or regulatory body or court, in each case having the force of law; 

 

	 	xii.	unless as otherwise provided, any reference to assignment of a person’s rights and/or obligations shall be construed to refer to assignment, transfer or novation of those rights and/or obligations;

  

	 	xiii.	any reference to the actions or omissions of agents, representatives or authorized persons shall refer only to actions or omissions taken in connection with the agency, representation or authorization (so that, for
example, an action or omission of a contractor for any Loan Party shall be the action of an agent, representative or authorized person of the Loan Parties only if taken in connection with the performance of its work under its contract with any Loan
Party involving work related to the Development, and shall not be the action or omission of an agent, representative or authorized person of the Loan Parties if taken under another contract with persons other than the Loan Parties involving work
unrelated to the Development); 

  

	 	xiv.	the omission of the word “any” or the phrase “if any” with respect to anything shall not imply that the thing exists or is required, notwithstanding the inclusion of such word or phrase
(for clarity) in other provisions; 

  

	 	xv.	any reference to an action being taken “pursuant to” an agreement or document, or any specified provision thereof, shall be construed to mean “pursuant to and in compliance with” the
requirements of such agreement, document or provision; 

  

	 	xvi.	in some instances, a word or reference that, pursuant to these rules of interpretation, is not necessary (for example, inclusion of both the singular and plural), may be included for emphasis or clarity, and any such
usage shall not give rise to any negative implication in relation to any other usage, which other usage shall nonetheless be interpreted strictly in accordance with the rules of interpretation set forth herein; 

  
 A-2 

	 	xvii.	unless the contrary indication appears, a reference to a time of day is a reference to the time of day in New York, New York, United States; and 

 

	 	xviii.	the words “hereof”, “herein”, “hereto” and “hereunder” and words of similar import when used in this Agreement shall refer to this Agreement as a whole
and not to any particular provision of this Agreement. 

  

	 	xix.	In respect of each of the defined terms in Section 1.3 (Definitions) of this Schedule A, as used in this Agreement, at any time when Loans and/or Senior Debt Commitments are not outstanding, all references
in this Agreement to each such defined term shall be to, and be required to meet the conditions or criteria, if any, included in, the definition provided for the equivalent of such defined term in each Senior Debt Instrument then in effect. A
defined term set forth in a Senior Debt Instrument will be deemed to be the equivalent of a defined term set forth in Section 1.3 (Definitions) of this Schedule A if the defined term in such Senior Debt Instrument (although not
necessarily the definition thereof) uses the same or interchangeable words as are used in Section 1.3 (Definitions) of this Schedule A for such defined term, or the same or interchangeable words plus words that identify such term as the
defined term applicable to a particular Senior Debt Instrument, such as “Indenture Permitted Liens” rather than simply “Permitted Liens.” 

 

	c.	Definitions 

 “Abandonment” means any of the following shall have
occurred: 
  

	 	i.	 the abandonment, suspension or cessation of all or substantially all of the activities related to the Development
or the abandonment, suspension or cessation of operations the Project Facilities, in each case, for a period in excess of 60 consecutive days (other than as a result of force majeure so long as the Borrower is diligently attempting to restart the
Development or the Project Facilities); provided that if this is not accompanied by a formal, public announcement by the Borrower of its intentions as set forth in clause (b) below, such abandonment, suspension or cessation shall not
have occurred unless, within 45 days following notice to the Borrower from the Security Trustee (who may be instructed by any Senior Creditor Group to deliver such notice) requesting the Borrower to deliver a certificate to the effect that it will
resume 

  
 A-3 

	 	
construction or operation as soon as is commercially reasonable, the Borrower has not delivered such certificate or resumed such activities or, if such certificate is delivered, the Borrower has
nevertheless not resumed such activities within 90 days following receipt of the notice from the Security Trustee; 

  

	 	ii.	a formal, public announcement by the Borrower of a decision to abandon, cease or indefinitely defer or suspend the Development for any reason; or 

 

	 	iii.	the Borrower shall make any filing with FERC giving notice of the intent or requesting authority to abandon the Development for any reason. 

“Acceptable Bank” means a bank whose long-term unsecured and unguaranteed debt is rated at least A- (or the equivalent rating) from S&P or Fitch or at least A-3 (or the equivalent rating) from Moody’s, and, in any case, with a combined capital surplus of at least
$1 billion. 
 “Acceptable Debt Service Reserve LC” means an irrevocable, standby letter of credit issued by an
Acceptable Bank for the benefit of the Security Trustee that includes the following material terms: 
 an expiration date
no earlier than 364 days following its issuance date; 
 allows the Security Trustee to make a drawdown of up to the stated
amount in each of the circumstances described in Section 4.9(d) (Acceptable Debt Service Reserve LC) of the Common Security and Account Agreement; and 

the reimbursement and other payment obligations with respect to such letter of credit are not for the account of any Loan
Party. 
 “Acceptable Lender” means any Sponsor or its Affiliate or a bank, financial institution, multilateral agency,
development financial institution, trust, Approved Fund, insurance company, investment or mutual fund or other entity that is an “accredited investor” (as defined in Regulation D under the Securities Act) or any Senior Creditor (other than
the Senior Noteholders that are not otherwise Acceptable Lenders) or any Affiliate of a Facility Lender or any other entity or Person, that in each case is regularly engaged in or established for the purpose of making, purchasing or investing in
loans, securities or other financial assets (including credit derivatives) in the ordinary course of business; provided that, in the case of trusts and funds that are not Approved Funds, such entity shall be experienced in the financing of
energy and natural resource projects. 
 “Access Information” has the meaning given in Section 23.9(f)(ii)
(Notices) of the Common Terms Agreement. 

  
 A-4 

 “Accession Agreement” means any accession agreement contemplated under the
Finance Documents, the form of which is included in either Schedule D (Forms of Accession Agreements) to the Common Security and Account Agreement or Schedule P – 1 (Replacement Facility Agent Accession Agreement) and Schedule P
– 2 (New Facility Agent Accession Agreement (Additional Senior Debt)) to the Common Terms Agreement. 
 “Account
Bank” means, initially, Mizuho Bank, Ltd. acting in its capacity as such (with any replacement to the initial Account Bank having a then-current credit rating at appointment by S&P at least equivalent to A+ or by Moody’s at least
equivalent to A1 and being subject to receipt of consent in accordance with Section 9.9(b) (Resignation, Removal and Replacement of Account Bank) of the Common Security and Account Agreement). 

“Account Bank Fee Letter” means the fee letter entered into between the Company and the Account Bank in respect of the fees
payable to the Account Bank in respect of its services to be performed as more fully described in the Common Security and Account Agreement and the other Security Documents. 

“Accounts” has the meaning given in Section 4.3(a) (Accounts) of the Common Security and Account Agreement. 

“Additional Proceeds Prepayment Account” is the account described in Section 4.3(a)(xi) (Accounts) of the Common
Security and Account Agreement. 
 “Additional Senior Debt” has the meaning given in Section 2.2(a)(i) (Incremental
Senior Debt) of the Common Security and Account Agreement. 
 “Advance” means a borrowing of a loan, issuance of
or drawing upon a letter of credit or the issuance of debt securities pursuant to any Senior Debt Instrument. 
 “Adverse Weather
Conditions” has the meaning given in the EPC Contract (T3). 
 “Affiliate” of any specified Person means any other
Person directly or indirectly Controlling or Controlled by or under direct or indirect common Control with such specified Person and “Affiliated” shall be construed accordingly. 

“Agreement” in each case where used means only the agreement in which the term is used. For the avoidance of doubt,
(a) any reference to an individual Senior Debt Instrument which is a Facility Agreement shall be deemed to include reference to the Common Terms Agreement; and (b) references to an Indenture, or to any individual Senior Debt Instrument
that is an Indenture, shall be deemed not to include reference to the Common Terms Agreement. 
 “Amortization Schedule”,
with respect to a Facility Agreement, has the meaning given in such Facility Agreement. 
 “Anti-Terrorism and Money Laundering
Laws” means any of the following (a) Section 1 of Executive Order 13224 of September 24, 2001, Blocking Property and Prohibiting Transactions With Persons Who Commit, Threaten to Commit, or Support Terrorism, (b) the
Terrorism Sanctions Regulations (Title 31 Part 595 of the US Code of Federal 

  
 A-5 

 
Regulations), (c) the Terrorism List Governments Sanctions Regulations (Title 31 Part 596 of the US Code of Federal Regulations), (d) the Foreign Terrorist Organizations Sanctions Regulations
(Title 31 Part 597 of the US Code of Federal Regulations), (e) the USA Patriot Act of 2001 (Pub. L. No. 107-56), (f) the US Money Laundering Control Act of 1986 (i.e., Laundering of Monetary
Instruments, 18 U.S.C. section 1956, and Engaging in Monetary Transactions in Property Derived from Specified Unlawful Activity, 18 U.S.C. section 1957), (g) the Bank Secrecy Act, 31 U.S.C. sections 5301 et seq., (h) the Financial
Recordkeeping and Reporting of Currency and Foreign Transactions Regulations (Title 31 Chapter X of the US Code of Federal Regulations), (i) any other similar federal Government Rule having the force of law and relating to money laundering,
terrorist acts or acts of war and (j) any regulations promulgated under any of the foregoing. 
 “Applicable Anti-Corruption
Laws” means the Foreign Corrupt Practices Act of 1977 and the rules and regulations thereunder and all laws, rules, and regulations of any jurisdiction applicable to the Borrower, the Borrower’s Subsidiaries or any Guarantor at
the relevant time concerning or relating to bribery or corruption. 
 “Applicable EPC Contract” means each of the EPC
Contract (T1/T2) and/or EPC Contract (T3), as applicable. 
 “Applicable PDE Assets” has the meaning given in
Section 6.4(a)(vi) (PDE Senior Debt) of the Common Terms Agreement. 
 “Approved Fund” means any Fund
administered or managed by (a) a Facility Lender, (b) an Affiliate of a Facility Lender or (c) an entity or an Affiliate of an entity that administers or manages a Facility Lender. 

“Assigned Agreements” has the meaning given in Section 3.2(b)(i) (Security Interests to be Granted by the Securing
Parties – Security Interests – General) of the Common Security and Account Agreement. 
 “Authorized
Investments” means any US Dollar denominated investments that are: 
  

	 	(a)	direct obligations of, or obligations the principal and interest on that are unconditionally guaranteed by, the United States of America (or any instrumentality thereof to the extent such obligations are backed by the
full faith and credit of the United States of America), in each case maturing within one year from the date of acquisition thereof; 

investments in marketable general obligations issued by any state of the United States of America or any political
subdivision of any such state or any public instrumentality thereof in each case maturing within one year from the date of acquisition thereof and having, at such date of acquisition, a credit rating of “A” or higher from S&P or from
Moody’s (or if at such time neither is issuing ratings, then a comparable rating of such other nationally recognized rating agency as shall be approved by the Security Trustee in its reasonable judgment); 

  
 A-6 

 commercial paper or tax exempt obligations having one of the two highest
ratings obtainable from Moody’s or S&P (or if at such time neither is issuing ratings, then a comparable rating of such other nationally recognized rating agency as shall be approved by the Security Trustee in its reasonable judgment) and,
in each case, maturing within one year of acquisition thereof; 
 investments in certificates of deposit, banker’s
acceptances and time deposits maturing or putable within one year from the date of acquisition thereof issued or guaranteed or placed with, and money market deposit accounts issued or offered by, any domestic office of (i) a commercial bank
organized under the laws of the United States of America or any state thereof or (ii) a licensed branch of a foreign bank organized under the laws of any member country of the Organization for Economic
Co-Operation and Development, in either case, that has a combined capital and undivided surplus and undivided profits of at least $500 million; 

fully collateralized repurchase agreements with a term of not more than 30 days for securities described in clause
(a) of this definition and entered into with a financial institution satisfying the criteria described in clause (d) of this definition; or 

money market funds that (i) comply with the criteria set forth in Securities and Exchange Commission Rule 2a-7 (or any successor rule) under the Investment Company Act of 1940; (ii) are rated either AAA by S&P and Aaa by Moody’s or at least 95% of the assets of which constitute Authorized Investments described
in clauses (a) through (e) of this definition and/or US Dollars; and (iii) have portfolio assets of at least $500 million. 

“Authorized Officer” means: (a) with respect to any Person that is a corporation, the chairman, president, senior vice
president, vice president, chief financial officer, chief operating officer, treasurer, assistant treasurer, attorney-in-fact, secretary or assistant secretary of such
Person, (b) with respect to any Person that is a partnership, the chairman, president, senior vice president, vice president, chief financial officer, chief operating officer, treasurer, assistant treasurer, attorney-in-fact, secretary or assistant secretary of such Person or a general partner of such Person and (c) with respect to any Person that is a limited liability company, the chairman, president,
senior vice president, chief financial officer, chief operating officer, vice president, treasurer, assistant treasurer, attorney-in-fact, secretary or assistant
secretary, the manager, the managing member or a duly appointed officer of such Person. 
 “Availability Period” means, with
respect to the Term Loans, the Term Loan Availability Period, and with respect to any other Loans, the period commencing on the date of first disbursement of such Loans and ending on the date of the termination or cancellation of all remaining
Facility Debt Commitments pursuant to the terms of the corresponding Facility Agreement. 
 “Bankruptcy” means with respect
to any Person, the occurrence of any of the following events, conditions or circumstances: 

  
 A-7 

	 	(a)	such Person shall file a voluntary petition in bankruptcy, or shall file any petition or answer or consent seeking any reorganization, arrangement, adjustment, composition, insolvency, liquidation, receivership,
dissolution or similar relief for itself under the Bankruptcy Code or any present or future applicable federal, state or other statute or law relating to bankruptcy, insolvency, reorganization or other relief for debtors generally, or shall apply
for or consent to the appointment of any trustee, receiver, conservator or liquidator of such Person or of all or any substantial part of its properties; 

a case or other proceeding shall be commenced against such Person in a court of competent jurisdiction without the consent or
acquiescence of such Person seeking any reorganization, arrangement, adjustment, composition, insolvency, liquidation, receivership, dissolution or similar relief with respect to such Person or its debts under the Bankruptcy Code or any present or
future applicable federal, state or other statute or law relating to bankruptcy, insolvency, reorganization or other relief for debtors generally, or seeking the appointment of a trustee, receiver, liquidator, custodian or other similar official of
it or any substantial part of its property, and such involuntary case or other proceeding shall remain undismissed or unstayed for a period of 60 consecutive days; 

a court of competent jurisdiction shall enter an order, judgment or decree approving a petition with respect to such Person
seeking a reorganization, arrangement, composition, readjustment, liquidation, dissolution or similar relief under the Bankruptcy Code, or any other present or future applicable federal, state or other statute or law relating to bankruptcy,
insolvency, reorganization or other relief for debtors, and such Person shall consent to the entry of such order, judgment or decree or such order, judgment or decree shall remain undischarged, unvacated or unstayed for 90 days (whether or not
consecutive) from the date of entry thereof, or any trustee, receiver, conservator or liquidator of such Person or of all or any substantial part of its property shall be appointed without the consent of such Person and such appointment shall remain
undischarged, unvacated and unstayed for an aggregate of 90 days (whether or not consecutive); 
 such Person shall admit
in writing its inability to pay its debts as they mature or shall generally not be paying its debts as they become due; 

such Person shall make a general assignment for the benefit of creditors or take any other similar action for the protection
or benefit of creditors; or 
 such Person shall take any corporate or partnership action for the purpose of effecting any
of the foregoing. 
 “Bankruptcy Code” means the United States Bankruptcy Reform Act of 1978 and codified as 11 U.S.C.
Section 11 et seq. 

  
 A-8 

 “Bankruptcy Default” has the meaning given in Section 6.2(c) (Initiation
of Security Enforcement Action – Bankruptcy Default) of the Common Security and Account Agreement. 
 “Bankruptcy
Proceeding” means: 
  

	 	(a)	any case, action or proceeding before any court or other governmental authority in relation to a Bankruptcy; or 

a general assignment under clause (e) of the definition of Bankruptcy, 

in each case of (a) and (b) above, undertaken under applicable US federal, state or foreign law, including the
Bankruptcy Code. 
 “Base Case Forecast” means the base case forecast attached as Schedule R (Base Case Forecast) to
the Common Terms Agreement, as may be updated from time to time in accordance with the Common Terms Agreement. 
 “Base Committed
Quantity” means not less than 554,067,500 MMBtu per annum, being the quantity of LNG contracted to be sold at plateau production pursuant to the Initial LNG SPAs and the Second Phase LNG SPAs; provided, in each case, that
(a) following the full payment of the required amount upon any LNG SPA Mandatory Prepayment, the Base Committed Quantity will be reduced to the quantity of LNG contracted to be sold at plateau production pursuant to the Qualifying LNG SPAs used
to calculate the amount of Senior Debt that the Borrower is not required to repay upon an LNG SPA Prepayment Event under Section 3.4(a)(iv) (Mandatory Prepayments – LNG SPA Payment Events) of the Common Terms Agreement and
(b) to the extent that (i) any other LNG SPA becomes a Qualifying LNG SPA or an existing Qualifying SPA is amended to increase the quantity of LNG contracted to be sold thereunder and (ii) incremental Senior Debt is incurred taking
into account cash flows from such additional Qualifying LNG SPA and/or increased contractual commitments under such existing Qualifying LNG SPA, the Base Committed Quantity will be increased, as of the date of such incremental Senior Debt
incurrence, to reflect the incremental quantity of LNG contracted to be sold at plateau production pursuant to all the Qualifying LNG SPAs then in effect (including such additional Qualifying LNG SPA and the increased commitments under such existing
Qualifying LNG SPA, as applicable). 
 “Base Rate” means, for any day, a fluctuating rate per annum equal to the highest of
(a) the Federal Funds Effective Rate plus 0.50%, (b) the prime rate published in The Wall Street Journal for such day; provided that if The Wall Street Journal ceases to publish for any reason such rate of interest,
“Base Rate” shall mean the prime lending rate as set forth on the Bloomberg page PRIMBB Index (or successor page) for such day (or such other service as determined by the Intercreditor Agent from time to time for purposes of providing
quotations of prime lending interest rates) and (c) the LIBOR for an interest period of one month plus 1%. Each change in the Base Rate shall be effective on the date the change in the relevant benchmark in this definition becomes
effective. 

  
 A-9 

 “Basis Swap” means a commodity derivative contract that is cash-settled based on
the difference between: (a) the price of natural gas at one particular pricing point and (b) the price of natural gas at a different delivery location or pricing point. 

“Bcf” means billions of cubic feet. 

“Borrower” means Cheniere Corpus Christi Holdings, LLC, a limited liability company organized under the laws of the State of
Delaware. The Borrower is also referred to as the “Company” under the Common Security and Account Agreement. 
 “Breakage
Costs” under a Facility Agreement has the meaning given in such Facility Agreement. 
 “Btu” means the amount of
heat equal to 1,055.056 joules. 
 “Business Day” means a day (other than a Saturday or Sunday) on which banks are generally
authorized to be open for business: 
  

	 	(a)	in relation to any determination of the LIBOR required under the Finance Documents, London; and 

in all other cases, The City of New York. 

“Business Interruption Insurance Proceeds” means all proceeds of any insurance policies required pursuant to the Schedule of
Minimum Insurance or otherwise obtained with respect to the Loan Parties or the Project Facilities insuring the Loan Parties against business interruption or delayed start-up. 

“Cash Flow” means, with respect to any period, all funds received or, as applicable in the relevant context, projected to be
received by the Loan Parties during such period, including: 
  

	 	(a)	fees and other amounts received by CCL under the LNG SPAs; 

 earnings on funds
held in the Secured Accounts (excluding interest and investment earnings that accrue on the amounts on deposit in any of the Senior Debt Service Reserve Account or any account established to prefund interest on any Senior Debt, if any, in any case,
that are not transferred to the Revenue Account pursuant to the Common Security and Account Agreement); 
 any amounts
deposited in the Insurance/Condemnation Proceeds Account to the extent applied to the payment of Operation and Maintenance Expenses or Project Costs in accordance with Article 5 (Insurance and Condemnation Proceeds and Performance Liquidated
Damages) of the Common Security and Account Agreement; 
 all cash paid to the Loan Parties during such period as
Business Interruption Insurance Proceeds; 

  
 A-10 

 proceeds from the transfer, sale or disposition of assets or rights of the Loan
Parties in the ordinary course of business in accordance with Section 12.17 (Sale of Project Property) of the Common Terms Agreement (other than as set forth in sub-clause (3) below) to the
extent such proceeds have been or will be used to pay Operation and Maintenance Expenses; 
 amounts paid under any
Material Project Agreement; 
 amounts received under Permitted Hedging Instruments other than in respect of interest
rates; and 
 solely with respect to calculation of the Historical DSCR, (I) all cash paid to the Borrower during the
applicable period from any direct or indirect owner of the Borrower by way of Equity Funding (in each case as otherwise permitted pursuant to the terms of the Finance Documents), and (II) in the case of the first Restricted Payment made
pursuant to Section 11 (Restricted Payments) of the Common Terms Agreement, any cash then on deposit in the Secured Accounts (without double counting any other amounts of Cash Flow taken into account in the calculation of the Historical
DSCR); and 
 with respect to the calculation of Fixed Projected DSCR for any purpose other than such calculation under
Section 11 (Restricted Payments) of the Common Terms Agreement, and for any period, any cash projected to be on deposit in the Secured Accounts at the commencement of such period as a result of a restriction on the making of Restricted
Payments applicable prior to such period (without double counting any other amounts of Cash Flow taken into account in the calculation of the Fixed Projected DSCR); 

but excluding, in each case: 
  

	 	(a)	all amounts required to be deposited in the Insurance/Condemnation Proceeds Account used to reimburse Equity Funding; 

  

	 	(b)	proceeds of third-party liability insurance; 

  

	 	(c)	proceeds of the sale of assets permitted by Section 12.17(c) or (l) (Sale of Project Property) of the Common Terms Agreement unless and until applied to procure a replacement for such assets;

  

	 	(d)	proceeds of Senior Debt and other Indebtedness (and corresponding amounts received by the Loan Parties pursuant to any guarantees) permitted by Section 12.14 (Limitation on Indebtedness) of the Common Terms
Agreement other than amounts received under Permitted Hedging Instruments included under clause (g) above; 

  

	 	(e)	except as provided in clause (h) above, Equity Funding received from the Sponsor or any direct or indirect holders of equity interests of the Borrower; and 

  
 A-11 

	 	(f)	any cash deposited into the Additional Proceeds Prepayment Account. 

 “Cash Flow
Available for Debt Service” means, for any period, the amount that is equal to (a) Cash Flow minus (b) Operation and Maintenance Expenses, in each case for such period; provided that Operation and Maintenance
Expenses included in the calculation of Historical DSCR and Fixed Projected DSCR will exclude (i) that portion of Operation and Maintenance Expenses arising prior to the Project Completion Date that are Project Costs, (ii) that portion of
Operation and Maintenance Expenses that are Required Capital Expenditures and (iii) Operation and Maintenance Expenses arising from and after the Project Completion Date relating to expenditure on items that were, as of the Project Completion
Date, outstanding or punch list items under the Applicable EPC Contracts that are paid out of Senior Debt or Equity Funding. 

“Catastrophic Casualty Event” has the meaning given in any Indenture. 

“CCL” means Corpus Christi Liquefaction, LLC, a limited liability company organized under the laws of the State of Delaware,
which will own and operate the Corpus Christi Terminal Facility. 
 “CCP” means Cheniere Corpus Christi Pipeline, L.P., a
limited partnership organized under the laws of the State of Delaware, which will own and operate the Corpus Christi Pipeline. 

“CCP Construction Contract” has the meaning given in Section 12.5(g) (Material Project Agreements) of the Common
Terms Agreement. 
 “CCP GP” means Corpus Christi Pipeline GP, LLC, a limited liability company organized under the laws of
the State of Delaware, which will be the general partner of CCP. 
 “CCP Pipeline Precedent Agreement” means the
transportation precedent agreement, dated as of July 21, 2014, as amended on May 13, 2015, between CCP and CCL pursuant to which firm transportation capacity is secured through the Corpus Christi Pipeline. 

“CEI Equity Contribution Agreement” means the Amended and Restated Equity Contribution Agreement, entered into between
the Borrower and the Sponsor as of the Second Phase Closing Date. 
 “CERCLA” means the Comprehensive Environmental
Response, Compensation and Liability Act (42 U.S.C. section 9604, et seq.) and rules and regulations issued thereunder. 

“Cessation Notice” has the meaning given in Section 15.3 (Cessation of Loan Facility Declared Default) of the
Common Terms Agreement. 
 “Change in Law” means the occurrence, after the Second Phase Closing Date, of any of the
following: 

  
 A-12 

	 	(a)	the adoption or taking effect of any law, rule, regulation or treaty; 

 any
change in any law, rule, regulation or treaty or in the administration, interpretation, implementation or application thereof by any governmental authority; or 

the making or issuance of any request, rule, guideline or directive (whether or not having the force of law) by any
governmental authority; 
 provided that, notwithstanding anything herein to the contrary, (x) the Dodd-Frank Wall Street Reform
and Consumer Protection Act and all requests, rules, guidelines or directives thereunder or issued in connection therewith and (y) all requests, rules, guidelines or directives promulgated by the Bank for International Settlements, the Basel
Committee on Banking Supervision (or any successor or similar authority) or the United States or foreign regulatory authorities, in each case pursuant to Basel III, shall in each case be deemed to be a “Change in Law”, regardless of
the date enacted, adopted or issued. 
 “Change of Control” means the Sponsor and its Affiliates (a) until one year
after the Project Completion Date, shall fail to own, directly or indirectly in the aggregate, more than 50% of the ownership interests in the Borrower or control, directly or indirectly, voting rights of more than 50% of the votes of all classes in
the Borrower or (b) more than one year after the Project Completion Date, shall fail to own, directly or indirectly in the aggregate, more than 25% of the ownership interests in the Borrower or control, directly or indirectly, voting rights of
more than 25% of the votes of all classes in the Borrower. 
 “Change Order” has the meaning given in the Applicable EPC
Contracts. 
 “Change Order Confirming Certificate” has the meaning given in Section 9.1(a)(i)(A) (Prohibited
Actions under EPC Contracts) of the Common Terms Agreement. 
 “Cheniere” has the same meaning as is given to
“Sponsor” below. 
 “Closing” means the satisfaction or waiver of all the conditions precedent set forth in
Section 4.1 (Conditions to Closing) of the original Common Terms Agreement, dated as of May 13, 2015, with respect to the Initial Senior Debt. 

“Closing Conditions Certificate” has the meaning given in Section 4.5(a) (Satisfaction of Conditions) of the
Common Terms Agreement. 
 “Closing Date” means May 13, 2015. 

“Closing Notice” has the meaning given in Section 4.5(a) (Satisfaction of Conditions) of the Common Terms
Agreement. 
 “CMI” means Cheniere Marketing, LLC, a limited liability company organized under the laws of the State of
Delaware. 

  
 A-13 

 “CMI Direct Agreement” means a Direct Agreement between CMI (UK) and the
Security Trustee with respect to the DES-Linked LNG SPA, in the form attached to the DES-Linked LNG SPA delivered to the Intercreditor Agent in connection with the
Second Phase Closing Date. 
 “CMI Export Authorization Letter” means the letter agreement, dated as of May 13, 2015,
between CMI and CCL. 
 “CMI Security Agreement” means the security agreement entered into by CMI (UK) for the benefit of
CCL, in the form attached to the DES-Linked LNG SPA delivered to the Intercreditor Agent in connection with the Second Phase Closing Date. 

“CMI (UK)” means Cheniere Marketing International LLP, a limited liability partnership organized under the laws of the United
Kingdom. 
 “CMI (UK) Base LNG SPA” means the Amended and Restated Base LNG Sale and Purchase Agreement (FOB), dated as of
November 28, 2014, as amended on June 26, 2015 and December 27, 2016, between CCL and CMI (UK). 
 “CMI (UK) LNG
SPAs” means the (a) CMI (UK) Base LNG SPA and (b) Amended and Restated Foundation Customer LNG Sale and Purchase Agreement (FOB), dated as of November 28, 2014, as amended on June 26, 2015 and December 27, 2016,
between CCL and CMI (UK), which has been terminated prior to the Second Phase Closing Date. 
 “Code” means the Internal
Revenue Code of 1986. 
 “Collateral” means any property right or interest subject to a Security Interest. 

“Collateral Parties” means the Securing Parties and Holdco, and “Collateral Party” shall have a corresponding
meaning. 
 “Collateral Records” means books, records, ledger cards, files, correspondence, customer lists, supplier lists,
blueprints, technical specifications, manuals, computer software and related documentation, computer printouts, tapes, disks and other electronic storage media and related data processing software and similar items that at any time evidence or
contain information relating to any of the Collateral or are otherwise necessary or helpful in the collection thereof or realization thereupon. 

“Commodity Exchange Act” means the Commodity Exchange Act, as amended (7 U.S.C. § 1 et seq.). 

“Common Collateral” means any property right or interest subject to a Security Interest granted or purported to be created by
or pursuant to Section 3.2(a) (Security Interests to be Granted by the Securing Parties – Pledge of Pledged Collateral), Section 3.2(b) (Security Interests to be Granted by the Securing Parties – Security Interests
– General) or Section 3.2(f) (Security Interests to be Granted by the Securing Parties – Real Property) of the Common Security and Account Agreement or pursuant to any Security Document other than the Common Security and
Account Agreement. 

  
 A-14 

 “Common Security and Account Agreement” means the Amended and Restated Common
Security and Account Agreement, dated as of the Second Phase Closing Date, among the Borrower, the Guarantors, each Senior Creditor Group Representative on its own behalf and on behalf of the relevant Senior Creditor Group, the Intercreditor Agent,
the Security Trustee and the Account Bank. 
 “Common Terms Agreement” means the Amended and Restated Common Terms
Agreement, dated as of the Second Phase Closing Date, among the Borrower, the Guarantors, the Term Loan Facility Agent and each other Facility Agent on behalf of its respective Facility Lenders, and the Intercreditor Agent providing common
representations, warranties, undertakings and events of default. For the avoidance of doubt, (i) any reference to an individual Senior Debt Instrument which is a Facility Agreement shall be deemed to include reference to the Common Terms
Agreement; and (ii) references to an Indenture, or to any individual Senior Debt Instrument that is an Indenture, shall be deemed not to include reference to the Common Terms Agreement. 

“Company” means Cheniere Corpus Christi Holdings, LLC, a limited liability company organized under the laws of the State of
Delaware. The Company is also referred to as the “Borrower” in certain Finance Documents and the “Issuer” in other Finance Documents. 

“Condemnation Proceeds” means any amounts and proceeds of any kind (including instruments) payable in respect of any Event of
Taking. 
 “Confidential Information” means all information received from a Loan Party, Holdco, the Sponsor or any of their
respective Affiliates or on their behalf relating to any of such entities, their businesses, the Project Facilities or the Development. 

“Confidential Information Memorandum” means the project information memorandum of March 12, 2018, or if it is
supplemented, amended or replaced with a later version, in each case in writing delivered to the Intercreditor Agent prior to Second Phase Closing Date, the form of such memorandum as it exists on the Second Phase Closing Date. 

“Connection Income Taxes” means Other Connection Taxes that are imposed on or measured by net income (however denominated) or
that are franchise Taxes or branch profits Taxes. 
 “ConocoPhillips” means ConocoPhillips Company, a corporation
incorporated in the State of Delaware. 
 “Constitutional Documents” means certificates of formation, limited liability
company agreements, partnership agreements, certificates of incorporation, bylaws or any similar entity organizational or constitutive document. 

“Construction Account” is the account described in Section 4.3(a)(iv) (Accounts) of the Common Security and
Account Agreement. 

  
 A-15 

 “Construction Budget and Schedule” means (a) the budget delivered pursuant
to Section 4.1(g) (Conditions to Second Phase Closing – Project Development) of the Common Terms Agreement (which shall be substantially in the form of budget attached as Schedule D-1
(Construction Budget and Schedule – Construction Budget) to the Common Terms Agreement), setting forth, on a monthly basis, the timing and amount of all projected payments of Project Costs through the date that is 90 days after
the projected date of Substantial Completion of the last Subproject to be completed under and as defined in the Applicable EPC Contracts and (b) the schedule delivered pursuant to Section 4.1(g) (Conditions to Second Phase Closing
– Project Development) of the Common Terms Agreement (which shall be substantially in the form of schedule attached as Schedule D-2 (Construction Budget and Schedule – Construction
Schedule) to the Common Terms Agreement), setting forth the proposed engineering, procurement, construction and testing milestone schedule for the Project Facilities’ development through the date that is 90 days following the projected date
of Substantial Completion of the last Subproject to be completed under the Applicable EPC Contracts; and in each of cases (a) and (b) as may be amended, supplemented, or otherwise modified to take into account any Change Orders permitted under
Section 9.1 (Prohibited Actions under EPC Contracts) of the Common Terms Agreement. It is acknowledged and understood that the “Construction Budget and Schedule” will be comprised of a budget and schedule in respect of the
Corpus Christi Terminal Facility (including the Second Phase Facilities) and a budget and schedule in respect of the Corpus Christi Pipeline and that all references in the Finance Documents to the “Construction Budget and Schedule” shall
be to such budgets and schedules collectively or to the budget and schedule applicable to the Project Facilities that are the subject of the applicable provision, as the context may require. 

“Consultants” has the meaning given in Section 13.1 (Appointment of Consultants) of the Common Terms Agreement.

 “Continuing” (including, with its corresponding meaning, the terms “Continuance” and
“Continuation”) means: 
  

	 	(a)	with respect to any Loan Facility Declared Default, Indenture Declared Default or other comparable event of default under any other Senior Debt Instrument, that such default has occurred without the need for
declaration, or been declared by required Senior Creditor action, in each case in conformity with the requirements of the Common Terms Agreement or such other Senior Debt Instrument, as the case may be, and no Cessation Notice shall have been given
with respect thereto; 

 with respect to any Unmatured Loan Facility Event of Default, Unmatured Indenture
Event of Default or other unmatured default under any other Senior Debt Instrument, that such unmatured default has occurred and has not been waived or cured; and 

with respect to any Loan Facility Event of Default, Indenture Event of Default or other event of default under any other
Senior Debt Instrument, that such event of default has occurred and has not been declared, waived or cured. 
 “Contract
Price” has the meaning given in the Applicable EPC Contracts. 

  
 A-16 

 “Control” of a Person means the power to direct the management and policies of
that Person, directly or indirectly, whether through the ownership of voting securities, by operation of law, by contract (including pursuant to a partnership or similar agreement) or otherwise; and the terms “Controlling” and
“Controlled” have corresponding meanings to the foregoing. 
 “Controlling Claimholders” means Senior
Creditor Group Representatives representing a Majority in Interest of the Senior Creditors. 
 “Copyright Licenses” means
any and all agreements, licenses and covenants providing for the granting of any right in or to any Copyright or otherwise providing for a covenant not to sue for infringement or other violation of any Copyright (whether a Loan Party is licensee or
licensor thereunder) including each agreement required to be listed in Schedule J (Intellectual Property) to the Common Security and Account Agreement under the heading “Copyright Licenses” (as such schedule may be amended or
supplemented from time to time). 
 “Copyrights” means all United States, and foreign copyrights (whether or not the
underlying works of authorship have been published), including copyrights in software and all rights in and to databases, all designs (including but not limited to industrial designs, Protected Designs within the meaning of 17 U.S.C. 1301 et.
seq. and Community designs), and all Mask Works (as defined under 17 U.S.C. 901 of the US Copyright Act), whether registered or unregistered, as well as all moral rights, reversionary interests, and termination rights, and, with respect to
any and all of the foregoing: 
  

	 	(a)	all registrations and applications therefor including the registrations and applications required to be listed in Schedule J (Intellectual Property) to the Common Security and Account Agreement under the
heading “Copyrights” (as such schedule may be amended or supplemented from time to time); 

 all extensions, renewals
and restorations thereof; 
 all rights to sue or otherwise recover for any past, present and future infringement or other
violation thereof; 
 all proceeds of the foregoing, including license fees, royalties, income, payments, claims, damages
and proceeds of suit now or hereafter due and/or payable with respect thereto; and 
 all other rights of any kind accruing
thereunder or pertaining thereto throughout the world. 
 “Corpus Christi Pipeline” means the
23-mile-long Gas pipeline and related compressor stations, meter stations and required interconnects, originating at the Corpus Christi Terminal Facility and terminating north of the City of Sinton, Texas, and
related facilities, as such facilities may be improved, replaced, modified, changed or expanded in accordance with the Finance Documents. 

  
 A-17 

 “Corpus Christi Terminal
Facility” means the facilities in San Patricio County and Nueces County in the vicinity of Portland, Texas, on the La Quinta Channel in the Corpus Christi Bay comprising, a liquefaction
facility comprised of three Trains, each with a nominal production capacity of approximately 4.5 mtpa, three LNG storage tanks, each with a working capacity of 160,000 cubic meters, and two marine berths, with related onsite and offsite utilities
and supporting infrastructure and as such facilities may be improved, replaced, modified, changed or expanded in accordance with the Finance Documents. 

“CP Fulfillment Date” has the meaning given in the applicable LNG SPA. 

“CTA Payment Date” means (i) each Quarterly Payment Date, (ii) the date for payment of Senior Debt Obligations
(including payment dates for the payment of interest) under or pursuant to any Facility Agreement, including the Common Terms Agreement and (iii) the scheduled Final Maturity Date under each Facility Agreement. 

“Date Certain” means the DFCD Deadline applicable under the PetroChina FOB LNG SPA. 

“Date of First Commercial Delivery” or “DFCD” has the meaning given in the applicable LNG SPA, and includes
the dates described as the “Corpus Christi T3 Completion Date” in the Trafigura LNG SPA and the “Designated Train SC Date” under the PetroChina FOB LNG SPA and the DES-Linked LNG SPA. 

“Debt Domain Website” has the meaning given in Section 12.7(b) (Notices) of the Common Security and Account
Agreement. 
 “Decision” means any notice, consent, decision, approval, instruction, judgment, direction, objection or
Modification. 
 “Declared Event of Default” means an Event of Default that has been declared or is otherwise deemed to have
been declared by a Senior Creditor Group Representative under its Senior Debt Instrument (acting on behalf of the Senior Creditors under, and in accordance with, such Senior Debt Instrument) or otherwise is deemed to have been declared in accordance
with the terms of the relevant Senior Debt Instrument. 
 “Default Rate” means a rate per annum equal to the rate that would
otherwise be applicable plus 2 %, or if there is no applicable interest rate, a rate per annum equal to the highest interest rate applicable to any then-outstanding Senior Debt plus 2%. 

“Defaulting Lender”, with respect to a Facility Agreement, has the meaning given in such Facility Agreement. 

“Defect Correction Period” has the meaning given in the Applicable EPC Contracts. 

“Delay Liquidated Damages” means any liquidated damages resulting from a delay with respect to the Project Facilities that are
required to be paid by the EPC Contractor or any other counterparty to a Material Project Agreement for or on account of any delay. 

  
 A-18 

 “DES-Linked LNG SPA” means the LNG SPA,
dated as of May 22, 2018, between CCL and CMI (UK). 
 “Development” means the financing, development, acquisition,
ownership, occupation, construction, equipping, testing, repair, operation, maintenance and use of the Project Facilities and the purchase, storage and sale of Gas and the storage and sale of LNG, the export of LNG from the Project Facilities (and,
if the Borrower so elects, the import of LNG to the extent any Loan Party has all necessary Permits therefor), the transportation of Gas to the Project Facilities by third parties, and the sale of other services or other products or by-products of the Project Facilities and all activities incidental thereto, in each case in accordance with the Transaction Documents. “Develop” and “Developed” shall have
corresponding meanings. 
 “Development Expenditures” means, for any period, the aggregate amount of all expenditures of the
Loan Parties payable during such period that, in accordance with GAAP, are or should be included in “purchase of property, plant and equipment” or similar items reflected in the consolidated statement of cash flows of the Loan
Parties. 
 “DFCD Deadline” means the date that is 60 days prior to the date on which a Termination Event (as defined in the
applicable LNG SPA) would occur under the applicable LNG SPA for any failure to achieve the DFCD by such date, in each case as extended by any waivers, modifications or amendments to its respective LNG SPA in accordance with Section 8.3
(Amendment of LNG SPAs) of the Common Terms Agreement, but without giving effect to cure rights under any agreement between the Security Trustee and such LNG Buyer. “DFCD Deadlines” shall have a corresponding meaning. 

“DIP Financing” has the meaning given in Section 10.5(b) (Certain Agreements with Respect to Bankruptcy) of the
Common Security and Account Agreement. 
 “DIP Financing Liens” has the meaning given in Section 10.5(b)(ii)
(Certain Agreements with Respect to Bankruptcy) of the Common Security and Account Agreement. 
 “DIP Lenders” has
the meaning given in Section 10.5(b) (Certain Agreements with Respect to Bankruptcy) of the Common Security and Account Agreement. 

“Direct Agreements” means: 
  

	 	(a)	the Direct Agreement (Pertamina LNG SPA), dated as of May 13, 2015, among Pertamina, CCL and Société Générale; 

 

	 	(b)	the Direct Agreement (Endesa LNG SPA (April 01, 2014)), dated as of May 13, 2015, among Endesa, CCL and Société Générale; 

 

	 	(c)	the Direct Agreement (Endesa LNG SPA (April 07, 2014)), dated as of May 13, 2015, among Endesa, CCL and Société Générale; 

  
 A-19 

	 	(d)	the Direct Agreement (Iberdrola LNG SPA), dated as of May 13, 2015, among Iberdrola, CCL and Société Générale; 

 

	 	(e)	the Direct Agreement (Gas Nat LNG SPA), dated as of May 13, 2015, among Gas Natural Fenosa, CCL and Société Générale; 

 

	 	(f)	the Direct Agreement (Gas Nat Guaranty), dated as of May 13, 2015, among Gas Natural SDG S.A., CCL and Société Générale; 

 

	 	(g)	the Direct Agreement (Woodside LNG SPA), dated as of May 13, 2015, among Woodside, CCL and Société Générale; 

 

	 	(h)	the Direct Agreement (Woodside Guaranty), dated as of May 13, 2015, among Woodside Petroleum Limited, CCL and Société Générale; 

 

	 	(i)	the Direct Agreement (EDF LNG SPA), dated as of May 13, 2015, among EDF, CCL and Société Générale; 

  

	 	(j)	the Acknowledgment and Consent Agreement with Lender, dated as of May 13, 2015, among EPC Guarantor, the Borrower, the Guarantors, Mizuho Bank, Ltd. and Société Générale;

  

	 	(k)	the Acknowledgment and Consent Agreement with Lender, dated as of May 13, 2015, among EPC Contractor, the Borrower, the Guarantors, Mizuho Bank, Ltd. and Société Générale;

  

	 	(l)	the Direct Agreement (CEI Equity Contribution Agreement), dated as of May 13, 2015, among the Sponsor, the Borrower and Société Générale; 

 

	 	(m)	the Direct Agreement, dated as of May 13, 2015, among CCL, ConocoPhillips and Société Générale; 

  

	 	(n)	the Direct Agreement (CCP Precedent Agreement), dated as of May 13, 2015, among CCP, CCL and Société Générale; 

 

	 	(o)	the Direct Agreement (CCL Management Services Agreement), dated as of May 13, 2015, among Cheniere Energy Shared Services, Inc., CCL and Société Générale; 

 

	 	(p)	the Direct Agreement (CCP Management Services Agreement), dated as of May 13, 2015, among Cheniere Energy Shared Services, Inc., CCP and Société Générale; 

 

	 	(q)	the Direct Agreement (CCL O&M Agreement), dated as of May 13, 2015, among Cheniere LNG O&M Services, LLC, CCL and Société Générale; 

 

	 	(r)	the Direct Agreement (CCP O&M Agreement), dated as of May 13, 2015, among Cheniere LNG O&M Services, LLC, CCP and Société Générale; 

  
 A-20 

	 	(s)	the Direct Agreement (Gas and Power Supply Services Agreement), dated as of May 13, 2015, among Cheniere Energy Shared Services, Inc., CCL and Société Générale; 

 

	 	(t)	the Direct Agreement (CMI Export Authorization Letter), dated as of May 13, 2015, among CCL, Cheniere Marketing, LLC and Société Générale; 

 

	 	(u)	the Direct Agreement (TGP Precedent Agreement), dated as of May 13, 2015, among CCL, TGP and Société Générale; 

 

	 	(v)	the Direct Agreement, dated as of May 13, 2015, among CCL, Transcontinental Gas Pipe Line Company, LLC and Société Générale; 

 

	 	(w)	the Direct Agreement (NGPL Precedent Agreement), dated as of June 29, 2015, between Natural Gas Pipeline Company of America LLC, CCL and Société Générale; 

 

	 	(x)	the Direct Agreement (NGPL Precedent Agreement), dated as of March 21, 2018, between Natural Gas Pipeline Company of America LLC, CCL and Société Générale; 

 

	 	(y)	the Direct Agreement, dated as of October 21, 2015, between GE Oil & Gas, Inc., CCL, and Société Générale; 

 

	 	(z)	the Direct Agreement, dated as of December 16, 2015, between Transcontinental Gas Pipe Line Company, LLC, CCL and Société Générale; 

 

	 	(aa)	the Direct Agreement in respect of the Construction Agreement, dated as of November 30, 2016, between Associated Pipe Line Contractors, Inc. and Société Générale, as Security Trustee,
and acknowledged and agreed by CCP; 

  

	 	(bb)	the Direct Agreement in respect of the Construction Agreement, dated as of November 29, 2016, between Ref-Chem, L.P. and Société Générale, as Security Trustee, and acknowledged and
agreed by CCP; 

  

	 	(cc)	the Direct Agreement in respect of the Construction Agreement, dated as of November 15, 2016, between Sunland Construction, Inc. and Société Générale, as Security Trustee, and
acknowledged and agreed by CCP; and 

  

	 	(dd)	the agreements described in Section 3.4 (Direct Agreements) of the Common Security and Account Agreement. 

“Direct Agreement” shall have a corresponding meaning. 

“Disbursement Account” means the account(s) of that name required to be established pursuant to Section 4.3
(Accounts) of the Common Security and Account Agreement. 

  
 A-21 

 “Disbursement Endorsement” means endorsement(s) to a Title Policy (dated not
earlier than two Business Days prior to the date of the requested Advance, as applicable), indicating that since the effective date of the Title Policy (or the date of the last preceding endorsement(s) to the Title Policy, if later), (1) there has
been no change in the state of the title to the insured estates or interests covered by the Title Policy (other than matters constituting Permitted Liens or matters otherwise approved by the Security Trustee), and (2) complying with Procedural
Rule P-9.b.4 of The Basic Manual of Rules, Rates and Forms for the Writing of Title Insurance in the State of Texas, and which endorsement(s) shall extend the effective date of the Title Policy to the date of
such endorsement(s) and increase the coverage of the Title Policy by an amount equal to the Advance then being made by stating the amount of coverage then existing under the policy, and with respect to the endorsement to be delivered for the
occurrence of the Project Completion Date in Section 14.1(f) (Conditions to Occurrence of the Project Completion Date – Survey and Title Policy Endorsement) of the Common Terms Agreement, the “Liability” paragraph
and the exception in Schedule B of the Title Policy for liens arising by reason of unpaid bills or claims for work performed or materials furnished in connection with improvements placed, or to be placed, upon the subject land shall be eliminated
from the policy by the issuance of the promulgated endorsement form containing the applicable promulgated language covering said elimination as provided in Procedural Rule P-8.b.2 of The Basic Manual of Rules,
Rates and Forms for the Writing of Title Insurance in the State of Texas. Such Disbursement Endorsement will be substantially in a form to be agreed and attached to the Common Terms Agreement. 

“Disbursement Request” means a drawdown notice, substantially in the form set forth in Schedule B (Disbursement Request
Form) to the Common Terms Agreement (or equivalent under another Senior Debt Instrument), given by the Borrower requesting an Advance with respect to a Loan in accordance with the terms of Section 2.3 (Disbursement Procedures) of the
Common Terms Agreement and/or the applicable Facility Agreement. 
 “Discharge Date” means: 

 

	 	(ee)	with respect to the Senior Debt Obligations under a Senior Debt Instrument, the date on which such Senior Debt Obligations thereunder shall have been unconditionally paid or discharged in full in US Dollars (other than
Senior Debt Obligations thereunder that by their terms survive and with respect to which no claim has been made by the applicable Senior Creditor), the Senior Debt Commitments thereunder shall have been terminated, expired or been reduced to zero
and all letters of credit thereunder (if any) shall have been terminated or collateralized in accordance with the provisions of such Senior Debt Instrument; 

with respect to the Senior Debt Obligations under a Permitted Senior Debt Hedging Instrument, the date on which such Senior
Debt Obligations thereunder shall have been unconditionally paid or discharged in full in US Dollars (other than Senior Debt Obligations thereunder that by their terms survive and with respect to which no claim has been made by the applicable Senior
Creditor) and such Permitted Senior Debt Hedging Instrument shall have terminated or expired; and 

  
 A-22 

 with respect to all Senior Debt Obligations, collectively, the date on which
each of the above shall have occurred with respect to each then-existing Senior Debt Instrument and Permitted Senior Debt Hedging Instrument and any other Senior Debt Obligations owing to the Intercreditor Agent, Facility Agents, Security Trustee or
other Secured Parties shall have been unconditionally paid or discharged in full in US Dollars (other than Senior Debt Obligations that by their terms survive and with respect to which no claim has been made by the applicable Secured Party). 

“DOE” means the US Department of Energy. 

“DSCR” means either Historical DSCR or Fixed Projected DSCR. 

“Early Works Equity Contribution Agreement” means the Equity Contribution Agreement, dated as of December 12, 2017,
between the Borrower and the Sponsor. 
 “EDF” means Électricité de France, S.A., a French utility company
that is an Initial LNG Buyer. 
 “EDF LNG SPA” means the LNG SPA, dated as of July 17, 2014, as amended on
February 24, 2015, between CCL and EDF. 
 “EDP” means EDP Energias de Portugal S.A., a Portuguese utility company that
is an Initial LNG Buyer. 
 “EDP LNG SPA” means the LNG SPA, dated as of December 18, 2014, as amended from time to
time, between CCL and EDP. 
 “Endesa” means Endesa S.A., a Spanish utility company that is an Initial LNG Buyer. 

“Enforcement Action” has the meaning given in Section 16.1(a) (Facility Lender Remedies for Loan Facility Declared
Events of Default – Enforcement Action) of the Common Terms Agreement. 
 “Enforcement Proceeds Account” has
the meaning given in Section 6.7(a) (Enforcement Proceeds Account) of the Common Security and Account Agreement. 

“Environmental Affiliate” means any Person, to the extent the Borrower could reasonably be expected to have liability as a
result of the Borrower retaining, assuming, accepting or otherwise being subject to liability for Environmental Claims relating to such Person, whether the source of the Borrower’s obligation is by contract or operation of Government Rule. 

“Environmental and Social Standards” means Environmental Laws and the Equator Principles III. 

  
 A-23 

 “Environmental Claim” means any administrative, regulatory or judicial action,
suit, judgment or other legal action (collectively, a “claim”) by any Person alleging or asserting liability for investigatory costs, response, cleanup or other remedial costs, legal costs, environmental consulting costs,
governmental environmental response costs, damages to natural resources or other property, personal injuries, fines or penalties arising out of (a) the presence, Release or threatened Release into the environment, of any Hazardous Material at
any location, whether or not owned by the Person against whom such claim is made, or (b) any violation of any Environmental Law. The term Environmental Claim will include any claim by any Person or Governmental Authority for enforcement,
cleanup, removal, response, remedial action or damages pursuant to any Environmental Law, and any claim by any third party seeking damages, contribution, indemnification, cost recovery, compensation or injunctive relief under any Environmental Law.

 “Environmental Laws” means all federal, state, and local statutes, laws, regulations, rules, judgments (including all
tort causes of action), orders or decrees, in each case as modified and supplemented and in effect from time to time concerning the regulation, use or protection of the environment, coastal resources, protected plant and animal species, human health
and safety as it relates to Hazardous Material exposure or to Releases or threatened Releases of Hazardous Materials into the environment, including ambient air, soil, surface water, groundwater, wetlands, coastal waters, land or subsurface strata,
or otherwise relating to the generation, manufacture, processing, distribution, use, treatment, storage, disposal, transport or handling of Hazardous Materials but excluding, for the avoidance of doubt, any laws relating to matters regulated by
FERC, DOE, Department of Transportation or OFAC. “Environmental Law” shall have a corresponding meaning. 
 “EPC
Change in Law” means “Change in Law” as defined in the Applicable EPC Contracts. 
 “EPC Contract” means
either the EPC Contract (T1/T2) or the EPC Contract (T3), and, collectively, the “EPC Contracts.” 
 “EPC Contract
(T1/T2)” means the fixed price separated turnkey engineering, procurement and construction contract between CCL and the EPC Contractor, dated as of December 6, 2013, pursuant to which the Initial Corpus Christi Terminal Facility will
be constructed, as modified from time to time based on permitted changes. 
 “EPC Contract (T3)” means the fixed price
separated turnkey engineering, procurement and construction contract between CCL and the EPC Contractor, dated as of December 12, 2017 pursuant to which the Second Phase Facilities will be constructed, as modified from time to time based on
permitted changes. 
 “EPC Contractor” means Bechtel Oil, Gas and Chemicals, Inc. 

“EPC Force Majeure” means “Force Majeure” as defined in the Applicable EPC Contracts. 

“EPC Guarantor” means the “Guarantor” as defined in the Applicable EPC Contracts. 

  
 A-24 

 “EPC Letter of Credit” means “Letter of Credit” as defined in the
Applicable EPC Contracts. 
 “Equity Funding” means contributions made to the Borrower in the form of (a) (i)
Subordinated Debt, (ii) equity funding from a direct or indirect shareholder, (iii) payment of costs in respect of the Development prior to May 13, 2015, (iv) Cash Flow applied or committed to be applied towards Project Costs prior to
the Project Completion Date, (v) Cash Flow applied or committed to be applied to Development Expenditure that is not committed under the Base Case Forecast or otherwise committed to fund development of Project Costs, and (vi) following the
Project Completion Date, Cash Flows applied towards other capital expenditures in respect of the Project Facilities; provided that such Cash Flows following the Project Completion Date would qualify to be distributed as Restricted Payments
based on meeting the conditions set forth in Section 11.1 (Conditions to Restricted Payments) of the Common Terms Agreement or are otherwise eligible to be used for Required Capital Expenditures,
(b) in-kind contributions of real property in the amount of $51 million that have been contributed prior to the Second Phase Closing Date, (c) additional
in-kind contributions of real property up to $28 million (which is based on the price paid to acquire such real property in arms’-length transactions with third parties) and $3 million related
to transaction fees and expenses and labor costs allocated to the Loan Parties with respect to activities related to the Second Phase Development and (d) contributions of early works and pre-construction
activities with respect to Train Three of $280 million contributed to CCL pursuant to the Early Works Equity Contribution Agreement and an assignment to CCL of the Technical Services Agreement as of the Second Phase Closing Date. 

“Equity Proceeds Account” is the account described in Section 4.3(a)(iii) (Accounts) of the Common Security
and Account Agreement. 
 “ERISA” means the Employee Retirement Income Security Act of 1974. 

“ERISA Affiliate” means any Person, or trade or business that is a member of any group of organizations: (a) described in
Section 414(b), (c), (m) or (o) of the Code of which the Borrower is a member and (b) solely for purposes of potential liability under Section 302(b) of ERISA and Section 412(b) of the Code and the lien created under
Section 303(k) of ERISA and Section 430(k) of the Code, described in Section 414(m) or (o) of the Code of which a Loan Party is a member. 

“ERISA Event” means: 
  

	 	(a)	any “reportable event,” as defined in Section 4043 of ERISA or the regulations issued thereunder with respect to a Plan, other than events for which the 30-day
notice period has been waived by current regulation under PBGC Regulation Subsections .27, .28, .29 or .31; 

the failure with respect to any Plan to meet the minimum funding requirements of Section 412 or 430 of the Code or
Section 302 or 303 of ERISA, whether or not waived; 

  
 A-25 

 the filing pursuant to Section 412(c) of the Code or Section 303 of
ERISA of an application for a waiver of the minimum funding standard with respect to any Plan; 
 the incurrence by a Loan
Party or any of its ERISA Affiliates of any liability under Title IV of ERISA with respect to the termination of any Plan; 

the filing of notice of intent to terminate a Plan or the treatment of a Plan amendment as a termination under
Section 4041 of ERISA; 
 the institution of proceedings to terminate a Plan by PBGC or to appoint a trustee to
administer any Plan; 
 the withdrawal by a Loan Party or any of its ERISA Affiliates from a multiple employer plan (within
the meaning of Section 4064 of ERISA) during a plan year in which it was a “substantial employer,” as such term is defined under Section 4064 of ERISA, upon the termination of a Multiemployer Plan or the cessation of operations
under a Plan pursuant to Section 4062(e) of ERISA; 
 the incurrence by a Loan Party or any of its ERISA Affiliates of
any liability with respect to the withdrawal or partial withdrawal from any Multiemployer Plan; 
 the attainment of any
Plan of “at risk” status within the meaning of Section 430 of the Code or Section 303 of ERISA; 
 the
receipt by a Loan Party or any ERISA Affiliate of any notice, or the receipt by any Multiemployer Plan from a Loan Party or any ERISA Affiliate of any notice, concerning the imposition of Withdrawal Liability or a determination that a Multiemployer
Plan is, or is expected to be, insolvent or in reorganization or in critical, endangered or seriously endangered status, within the meaning of the Code or Title IV of ERISA; 

the failure of a Loan Party or any ERISA Affiliate to pay when due any amount that has become liable to the PBGC, any Plan or
trust established thereunder pursuant to Title IV of ERISA or the Code; 
 the adoption of an amendment to a Plan requiring
the provision of security to such Plan pursuant to Section 436(f) of the Code; 
 a Loan Party engages in a
“prohibited transaction” within the meaning of Section 4975 of the Code or Section 406 of ERISA that is not otherwise exempt by statute, regulation or administrative pronouncement; or 

the imposition of a lien under ERISA or the Code with respect to any Plan or Multiemployer Plan. 

“Escrowed Amounts” has the meaning given in each Applicable EPC Contract. 

  
 A-26 

 “Event of Default” means a Loan Facility Event of Default, an Indenture Event of
Default or any comparable Loan Party event of default under any other Senior Debt Instrument entered into after the date of the Common Security and Account Agreement. 

“Event of Taking” means any taking, seizure, confiscation, requisition, exercise of rights of eminent domain, public
improvement, inverse condemnation, condemnation or similar action of or proceeding by any Governmental Authority relating to all or any part of the Project Facilities, any equity interests in the Loan Parties or any other part of the Security
Interests. 
 “Excluded Accounts” means Excluded Unsecured Accounts and any escrow account established under the EPC
Contracts. 
 “Excluded Assets” has the meaning given in Section 3.2(g) (Security Interests to be Granted by the
Securing Parties – Excluded Assets) of the Common Security and Account Agreement. 
 “Excluded Swap
Obligation” means, with respect to any Loan Party, any Swap Obligation if, and to the extent that, all or a portion of the guarantee of such Loan Party of, or the grant by such Loan Party of a security interest to secure, such Swap
Obligation (or any guarantee thereof) is or becomes illegal under the Commodity Exchange Act or any rule, regulation or order of the Commodity Futures Trading Commission (or the application or official interpretation of any thereof) by virtue of
such Loan Party’s failure for any reason to constitute an “eligible contract participant” as defined in the Commodity Exchange Act and the regulations thereunder at the time the guarantee of such Loan Party or the grant of such
security interest becomes effective with respect to such Swap Obligation. If a Swap Obligation arises under a master agreement governing more than one swap, such exclusion shall apply only to the portion of such Swap Obligation that is attributable
to swaps for which such guarantee or security interest is or becomes illegal. 
 “Excluded Tax” means any of the following
Taxes imposed on or with respect to a Finance Party or required to be withheld or deducted from a payment to a Finance Party: 
  

	 	(a)	Taxes imposed on or measured by net income (however denominated), franchise Taxes, and branch profits Taxes, in each case, (i) imposed as a result of such Finance Party being organized under the laws of, or having
its principal office or, in the case of any Facility Lender, its applicable lending office located in, the jurisdiction imposing such Tax (or any political subdivision thereof) or (ii) that are Other Connection Taxes; 

in the case of a Facility Lender, US federal withholding tax imposed on amounts payable to such Facility Lender pursuant to a
law in effect at the time such Facility Lender becomes a party to a Facility Agreement or designates a new lending office (other than pursuant to an assignment or new lending office designation request by the Borrower), except to the extent that
such Facility Lender (or its assignor, if any) was entitled, at the time of such designation of a new lending office (or 

  
 A-27 

 
assignment), to receive additional amounts from the Borrower with respect to such withholding tax pursuant to the Facility Agreement provisions described in Section 21.1 (Withholding Tax Gross-Up) of the Common Terms Agreement; 
 Taxes attributable to a Facility
Lender’s failure to comply with the provisions described in Section 21.5 (Status of Facility Lenders and Facility Agents) of the Common Terms Agreement; or 

US federal withholding Taxes imposed under FATCA. 

“Excluded Unsecured Accounts” has the meaning given in Section 3.2(g)(iv) (Security Interests to be Granted by the
Securing Parties – Excluded Assets) of the Common Security and Account Agreement. 
 “Existing Facility
Lender” has the meaning given in Section 19.6 (Transfers by a Facility Lender) of the Common Terms Agreement. 

“Expansion” has the meaning given in Section 7.2(a) (Expansion Contracts) of the Common Terms Agreement (or
equivalent provision in any other Senior Debt Instrument). 
 “Expansion Construction Account” has the meaning given in
Section 4.5(k) (Deposits and Withdrawals – Expansion Accounts) of the Common Security and Account Agreement. 

“Expansion Disbursement Account” has the meaning given in Section 4.5(k) (Deposits and Withdrawals – Expansion
Accounts) of the Common Security and Account Agreement. 
 “Expansion Equity Proceeds Account” has the meaning given in
Section 4.5(k) (Deposits and Withdrawals – Expansion Accounts) of the Common Security and Account Agreement. 

“Expansion Senior Debt” has the meaning given in Section 6.5 (Expansion Senior Debt) of the Common Terms
Agreement. 
 “Export Authorization” means a long-term, multi-contract authorization issued by the DOE to export LNG from
the Corpus Christi Terminal Facility, including the FTA Authorization and Non-FTA Authorization. 

“Export Authorization Remediation” has the meaning given in Section 8.2(a)(ii)(A) (LNG SPA Mandatory Prepayment)
of the Common Terms Agreement. 
 “Facility Agent” means the facility agent under any Facility Agreement. 

“Facility Agreements” means the Term Loan Facility Agreement and any individual loan facility agreements (not including any
Indenture or facility agreement for a “term loan B” financing that the Borrower has elected to treat as an Indenture) evidencing permitted 

  
 A-28 

 
Replacement Senior Debt, Working Capital Debt, PDE Senior Debt and Expansion Senior Debt (and for which the Facility Agents have acceded to the Common Terms Agreement and to the Common Security
and Account Agreement), in each case as required thereby, and “Facility Agreement” shall have a corresponding meaning. 

“Facility Debt Commitment” means the aggregate principal amount of Loans and letters of credit any Facility Lender is
committed to disburse to or issue on behalf of the Borrower under any Facility Agreement. 
 “Facility Lenders” means the
Term Lenders and the lenders under any other Facility Agreements entered into after the Signing Date, and “Facility Lender” shall have a corresponding meaning. 

“Fair Labor Standards Act” means the Fair Labor Standards Act of 1938. 

“FATCA” means Sections 1471 through 1474 of the Code, as of the Signing Date (or any amended or successor version that is
substantively comparable and not materially more onerous to comply with), any current or future regulations or official interpretations thereof and any agreement entered into pursuant to Section 1471(b)(1) of the Code. 

“Federal Funds Effective Rate” means, for any day, the weighted average (rounded upwards, if necessary, to the nearest 1/100
of 1%) of the rates on overnight federal funds transactions with members of the Federal Reserve System, as published on the next succeeding Business Day by the Federal Reserve Bank of New York, or, if such rate is not so published for any day that
is a Business Day, the average (rounded upwards, if necessary, to the next 1/100 of 1%) of the quotations for such day for such transactions received by the Intercreditor Agent from three federal funds brokers of recognized standing selected by it.

 “Federal Reserve Bank” means each of the 12 Reserve Banks under the United States Federal Reserve System, or any
successor thereto. 
 “Federal Reserve Board” means the Board of Governors of the United States Federal Reserve System, or
any successor thereto. 
 “Fee Letters” means the SG Agency Fee Letter, the Account Bank Fee Letter and any other similar
fee letter, fee agreement or other fee arrangement between a Securing Party and a Facility Agent, or between a Securing Party and any of the Account Bank, Intercreditor Agent or Security Trustee, that may be entered into from time to time after the
date of the Common Security and Account Agreement. 
 “FERC” means the US Federal Energy Regulatory Commission. 

“FERC Order” means the Order Granting Authorization Under Section 3 of the Natural Gas Act and Issuing
Certificates (149 FERC ¶ 61,283 (2014)) issued December 30, 2014 by FERC pursuant to Section 3 and Section 7 of the Natural Gas Act, granting the applications filed on August 31, 2012, in Docket No. CP12-507-000 and Docket No. CP12-508-000 to site, construct and operate the Corpus Christi
Terminal Facility and to construct and operate the Corpus Christi Pipeline. 

  
 A-29 

 “Final Completion” has the meaning given in each Applicable EPC Contract. 

“Final Maturity Date” means, with respect to each of the Facility Agreements, the date on which all Senior Debt under such
Facility Agreement comes due, whether upon acceleration or otherwise. 
 “Finance Documents” means, together, each of the
following documents: 
  

	 	(a)	the Common Terms Agreement; 

 the Common Security and Account Agreement; 

the individual Facility Agreements; 

any Indenture; 
 the Security
Documents; 
 the Direct Agreements; 

the Senior Notes; 
 the
Intercreditor Agreement; 
 any fee letters with parties providing financing (other than any Equity Funding); 

any Permitted Senior Debt Hedging Instrument; 

the Second Phase Finance Documents; and 

any other document the Intercreditor Agent (acting on the instructions of the Requisite Intercreditor Parties) designates,
with the consent of the Borrower (such consent not to be unreasonably withheld), a Finance Document; 
 provided that when used with
respect to the Facility Lenders, such term shall not include any Indenture or Senior Notes and when used with respect to the Senior Notes, such term shall not include the Common Terms Agreement, Facility Agreement or any other Finance Document to
which the Indenture Trustee is not a party or under which security is not intended to be granted for the benefit of the Senior Notes. 

“Finance Party” means each Facility Lender, the Intercreditor Agent, the Security Trustee, each Senior Creditor Group
Representative (in its own right and in its capacity as agent), each Hedging Bank and the Account Bank. 
 “First LNG Cargo”
means the First LNG Cargo as described in Schedule A-1 (Scope of Work) of each Applicable EPC Contract. 

  
 A-30 

 “First of Month Index” means a price which represents the most commonly traded
fixed price at a major trading point and as published by Inside FERC Gas Market Report (“IFERC” or any successor publication widely used to establish index pricing in the US natural gas trading market). 

“First Repayment Date”, with respect to the Term Loan Facility Agreement, has the meaning given in the Term Loan Facility
Agreement. 
 “Fitch” means Fitch Ratings Ltd. or any successor thereto. 

“Fixed-Floating Futures Swap” means a contract which entitles the buyer of the contract to pay a fixed price for natural gas
and the seller to pay a floating price equal to the final settlement price of the Futures Contract settlement prices. The Fixed-Floating Futures Swap shall be settled financially, via exchange of cash payment at the expiration of the underlying
Futures Contract, rather than physically. 
 “Fixed Projected DSCR” means, for each Quarterly Payment Date during the
applicable period beginning no earlier than the First Repayment Date, the ratio of: 
  

	 	(a)	the Cash Flow Available for Debt Service projected for such period, calculated solely to reflect (i) the fixed price component under Qualifying LNG SPAs then in effect, which, for the avoidance of doubt, shall not
take into account variable costs of the Development related to the variable price component under such Qualifying LNG SPAs, (ii) expected interest and investment earnings paid to the Loan Parties during such period, (iii) amounts expected
to be paid to the Loan Parties during such period as Business Interruption Insurance Proceeds and (iv) only the fixed expenses that could reasonably be expected to be incurred if the counterparties to the Qualifying LNG SPAs then in effect were
not lifting any cargoes from the Development; to 

 Senior Debt Obligations projected to be paid in such
period (other than (i) pursuant to voluntary prepayments or mandatory prepayments, (ii) Senior Debt due at maturity, (iii) Working Capital Debt, (iv) LC Costs, (v) interest in respect of Senior Debt and Senior Debt
Obligations under any Permitted Hedging Instrument in respect of interest rates, in each case projected to be paid prior to the end of the Term Loan Availability Period and (vi) net payable amounts under Permitted Hedging Instruments that are
not in respect of interest rates). 
 provided that, with respect to Section 11 (Restricted Payments) of the Common Terms
Agreement, the ratio for calculating Fixed Projected DSCR shall be: 
  

	 	(a)	all of the Cash Flow Available for Debt Service projected for such period; to 

Senior Debt Obligations projected to be paid in such period (other than (i) pursuant to voluntary prepayments or
mandatory prepayments, (ii) Senior Debt due at maturity, (iii) Working Capital Debt, (iv) LC Costs, (v) interest in respect of Senior Debt and Senior Debt Obligations under any Permitted Hedging Instrument in respect of interest
rates, in each case projected to be paid prior to the end of the Term Loan Availability Period and (vi) net payable amounts under Permitted Hedging Instruments that are not in respect of interest rates). 

  
 A-31 

 “Flood Certificate” has the meaning given in Section 12.28 (Insurance
Covenant) of the Common Terms Agreement. 
 “Flood Program” has the meaning given in Section 12.28 (Insurance
Covenant) of the Common Terms Agreement. 
 “FOB” means “free on board.” 

“FTA Authorization” means the DOE/FE Order No. 3164 (2012), as amended by DOE/FE Order No.
3164-A (2014), granting CMI and CCL a long-term, multi-contract Export Authorization to export LNG by vessel from the Corpus Christi Terminal Facility to any country which has, or in the future develops, the
capacity to import LNG via ocean-going vessels and with which the United States has, or in the future enters into, a free trade agreement requiring national treatment for trade in natural gas. 

“Fund” means any Person that is (or will be) engaged in making, purchasing, holding or otherwise investing in commercial loans
and similar extensions of credit. 
 “Funds Transfer Agreement” has the meaning given in Section 3.2(d)(v)(F)
(Provisions Related to Secured Accounts) of the Common Security and Account Agreement. 
 “Futures Contract” means a
contract which entitles the buyer of the contract to claim physical delivery of natural gas from the seller at a specified contract delivery point at a specified date in the future and entitles the seller to deliver the physical commodity to the
buyer under the same conditions. The price between the buyer and the seller shall be transacted at the price of final settlement on a monthly basis. 

“GAAP” means generally accepted accounting principles in the jurisdiction in which the relevant party’s financial
statements are prepared or International Accounting Standards/International Financial Reporting Standards, as in effect from time to time. 

“Gas” means any hydrocarbon or mixture of hydrocarbons consisting essentially of methane and other paraffinic hydrocarbons and
non-combustible gases in a gaseous state. 
 “Gas and Power Supply Services
Agreement” means the gas and power supply services agreement, dated as of May 13, 2015, between CCL and Cheniere Energy Shared Services, Inc., pursuant to which Cheniere Energy Shared Services, Inc. serves as the Supply Manager in
respect of power and Gas requirements of the Development. 
 “Gas Hedge Provider” means any party (other than the Loan
Parties or their Affiliates) that is a party to a Gas Hedging Instrument that is secured pursuant to the Security Documents. 

  
 A-32 

 “Gas Hedging Instruments” means Gas swaps, options contracts, futures contracts,
options on futures contracts, caps, floors, collars or any other similar arrangements entered into by any Loan Party related to movements in Gas prices. 

“Gas Natural Fenosa” means Gas Natural Fenosa LNG SL, a Spanish utility company that is an Initial LNG Buyer. 

“Gas Sourcing Plan” means the plan set forth in Schedule K (Gas Sourcing Plan) of the Common Terms Agreement, as
updated semi-annually by delivery by the Borrower of an updated plan, and related attachments and exhibits, by the Borrower to the Intercreditor Agent. 

“Government Rule” means any statute, law, regulation, ordinance, rule, judgment, order, decree, directive, requirement of, or
other governmental restriction or any similar binding form of decision of or determination by, or any interpretation or administration of any of the foregoing by, any Governmental Authority, including all common law, which is applicable to any
Person, whether now or hereafter in effect. 
 “Governmental Authorities” means all supra-national, federal, state and local
authorities or bodies including in each case any and all agencies, branches, departments and administrative and other subdivisions thereof, and all officials, agents and representatives of each of the foregoing, and “Governmental
Authority” shall have a corresponding meaning. 
 “Guaranteed Substantial Completion Date” has the meaning given in
the Applicable EPC Contract. 
 “Guarantor Interests” means the limited liability company interests in CCL and CCP GP and
the limited and general partnership interests in CCP. 
 “Guarantors” means CCL, CCP and CCP GP, each of which is a direct
or indirect wholly owned subsidiary of the Borrower and operated together with the Borrower as a single unit, and any other subsidiary of the Borrower that accedes to the Common Security and Account Agreement from time to time as permitted under the
Finance Documents then in effect as a Guarantor for the benefit of all Senior Creditors, pursuant to Section 11.15 (Additional Guarantors) of the Common Security and Account Agreement. 

“Hague Securities Convention” means the Convention on the Law Applicable to Certain Rights in Respect of Securities Held with
an Intermediary (concluded July 5, 2006), which became effective in the United States on April 1, 2017. 
 “Hazardous
Materials” means: 
  

	 	(a)	petroleum or petroleum byproducts, flammable materials, explosives, radioactive materials, friable asbestos, urea formaldehyde foam insulation and polychlorinated biphenyls; 

  
 A-33 

 any chemicals, other materials, substances or wastes that are now or hereafter
become defined as or included in the definition of “hazardous substances,” “hazardous wastes,” “hazardous materials,” “extremely hazardous wastes,” “restricted hazardous wastes,” “toxic
substances,” “toxic pollutants,” “contaminants,” “pollutants” or words of similar import under any Environmental Law; and 

any other chemical, material, substance or waste that is now or hereafter regulated under or with respect to which liability
may be imposed under Environmental Laws. 
 “Hedging Bank” means a hedging bank that has entered into a Permitted Hedging
Instrument and that has entered into or that accedes to the Common Security and Account Agreement, and: 
  

	 	(a)	as of the date of execution or assignment of any Permitted Hedging Instrument, any of the following: (i) any Senior Creditor as of the date of the Common Terms Agreement or (ii) any Affiliate of any Person
listed in the foregoing sub-clause (a)(i) of this definition; or 

as of the date of execution or assignment of any Permitted Hedging Instrument, any of the following: (i) any Person who
becomes a Senior Creditor after the date of the Common Terms Agreement or (ii) any Affiliate of any Person listed in the foregoing sub-clause (b)(i) of this definition, in each case, with a credit rating
(or a guarantee from a Person with a credit rating) of at least A- from S&P or Fitch or at least A-3 from Moody’s. 

“Hedging Excess Amount” has the meaning given in Section 12.22(c) (Hedging Arrangements) of the Common Terms
Agreement. 
 “Hedging Instruments” means: 
  

	 	(a)	Interest Rate Hedging Instruments; 

 (i) Gas Hedging Instruments and (ii) Power Hedging
Instruments; and 
 such other derivative transactions of a similar nature that any Loan Party enters into to hedge risks
of any commercial nature. 
 “Hedging Termination Amount” means any Permitted Hedging Liability falling due as a result of
the termination of a Permitted Hedging Instrument or of any other transaction thereunder. 
 “Historical DSCR” means for any
period of up to twelve months ending on a Quarterly Payment Date, first measured as of the First Repayment Date, the ratio of: 
  

	 	(a)	the Cash Flow Available for Debt Service for such period; to 

  
 A-34 

	 	(b)	Senior Debt Obligations incurred or paid in such period, including on the Payment Date that is the last day of such Historical DSCR period (other than (i) pursuant to voluntary prepayments or mandatory prepayments,
(ii) LC Costs, (iii) interest in respect of the Senior Debt and Senior Debt Obligations under Permitted Hedging Instruments in respect of interest rates, in each case paid prior to the end of the Term Loan Availability Period,
(iv) net amounts payable under Permitted Hedging Instruments that are not in respect of interest rates, (v) Hedging Termination Amounts and (vi) Working Capital Debt); 

provided that for any DSCR calculation performed prior to the first anniversary of the First Repayment Date the calculation of the
numerator and denominator will be based on the number of months elapsed since the First Repayment Date. 
 “Holdco” means
Cheniere CCH HoldCo I, LLC. 
 “Holdco Pledge Agreement” has the meaning given in Section 3.3 (Security Interests to
be Granted by Holdco) of the Common Security and Account Agreement. 
 “Holder” of a Senior Debt Obligation shall
be determined by reference to the provisions of the relevant Senior Debt Instrument or Permitted Senior Debt Hedging Instrument, as applicable, setting forth who shall be deemed to be lenders, creditors, holders or owners of the debt obligation
governed thereby. 
 “Iberdrola” means Iberdrola, S.A., a Spanish utility company that is an Initial LNG Buyer. 

“Illegality Event” has the meaning given in Section 19.5(b) (Mitigation Obligations; Replacement of Lenders) of
the Common Terms Agreement. 
 “Impairment” means, with respect to any Permit: 

 

	 	(a)	the rescission, revocation, staying, withdrawal, early termination, cancellation, repeal or invalidity thereof or otherwise ceasing to be in full force and effect; 

the suspension or injunction thereof; or 

the inability to satisfy in a timely manner stated conditions to effectiveness. 

“Impair” and “Impaired” shall have a corresponding meaning. 

“Indebtedness” of any Person, at any date, means: 
  

	 	(a)	all obligations to repay borrowed money; 

 all obligations to pay money
evidenced by bonds, debentures, notes, banker’s acceptances, loan agreements or other similar instruments; 
 all
obligations to pay the deferred purchase price of property or services (excluding current accounts payable incurred in the ordinary course of business); 

all capital lease obligations of such Person; 

  
 A-35 

 all obligations, contingent or otherwise, issued for the account of such
Person, in respect of letters of credit, bank guarantees, surety bonds, letters of guarantee and similar instruments; 

all obligations of such Person under any Hedging Instruments (including any Hedging Termination Amounts); 

all guarantees by such Person of Indebtedness of others; 

any obligations of such Person to purchase or repurchase securities or other property which arises out of or in connection
with the sale of the same or substantially similar securities or property; 
 all obligations under conditional sale or
other title retention agreements related to property acquired by such Person (even though the rights and remedies of the seller or lender under such agreement in the event of default are limited to repossession or sale of property or are otherwise
limited in recourse); 
 all Indebtedness of others secured by (or for which the holder of such Indebtedness has an
existing right, contingent or otherwise, to be secured by) any Lien on property owned or acquired by such Person, whether or not the Indebtedness secured thereby has been assumed; 

all obligations to purchase, redeem, retire, defease or otherwise make any payment in respect of any equity interests of such
Person or any other Person or any warrants, rights or options to acquire such equity interests, which in the case of redeemable preferred interests, being valued at the greater of its voluntary or involuntary liquidation preference plus accrued and
unpaid dividends; and 
 all Indebtedness of any other entity (including any partnership in which such Person is a general
partner) to the extent such Person is liable therefor as a result of such Person’s ownership interest in or other relationship with such entity, except to the extent the terms of such Indebtedness provide that such Person is not liable
therefor. 
 “Indemnified Taxes” means (a) Taxes, other than Excluded Taxes, imposed on or with respect to any payment
made by or on account of any obligation of a Loan Party under or in connection with any Finance Document (other than any Indenture or Senior Notes) and (b) to the extent not otherwise described in clause (a) of this definition, Other
Taxes. 
 “Indenture” means any indenture to be entered into between the Borrower and the Indenture Trustee pursuant to
which one or more series of Senior Notes will be issued, or, at the Borrower’s option, a facility agreement for a “term loan B” financing, pursuant to which Senior Debt will be incurred. No reference in any Finance Document to an
Indenture or the Senior Notes or a “term loan B” shall mean or imply that entry into an Indenture or issuance of the Senior Notes or entry into a “term loan B” is required. For the avoidance of doubt, if at any time Senior Notes
have not been issued or are not outstanding and there is no “term loan B”, any reference to satisfaction of the requirements of any Indenture or Senior Notes or the “term loan B” (and any reference to an Indenture Trustee) shall
be ignored. 

  
 A-36 

 “Indenture Declared Default” means an Indenture Event of Default which is
declared by the Indenture Trustee (acting on behalf of the Senior Noteholders in accordance with such Indenture) to be an event of default under an Indenture or is otherwise deemed to have been declared to be an event of default in accordance with
the terms of the Indenture. 
 “Indenture Event of Default” means any of the events of default set out in an Indenture and
defined as “Indenture Events of Default.” 
 “Indenture Projected Fixed DSCR” has the meaning assigned in the
applicable Indenture. 
 “Indenture Trustee” means any trustee appointed in the role of indenture trustee under any
Indenture or, with respect to a “term loan B” financing that the Borrower has elected to be treated as an Indenture, any administrative or other facility agent. 

“Independent Accountants” means any independent firm of accountants of recognized standing in the relevant jurisdiction. 

“Independent Engineer” means Lummus Consultants International Limited or any independent replacement environmental and social
and engineering consulting firm selected in accordance with Section 13.2 (Replacement and Fees) of the Common Terms Agreement. 

“Index Swap” means a contract which entitles the buyer of the contract to pay one index price (e.g. First of Month
Index) and entitles the seller to pay a different index price (e.g. the daily average). The index swap is settled financially via exchange of cash payment at the expiration of the underlying Futures Contract. 

“Individual Senior Noteholder Secured Accounts” has the meaning given in Section 3.2(c) (Security Interests to be
Granted by the Securing Parties – Security Interests – Individual Senior Noteholder Secured Accounts) of the Common Security and Account Agreement. 

“Industry Standards” means the technical standards promulgated by the American Petroleum Institute, the American Gas
Association, the American Society of Mechanical Engineers, the ASTM (formerly the American Society for Testing and Materials), or the National Fire Protection Association (NFPA). 

“Initial Advance” means the first Advance of the Term Loans following the occurrence of the Second Phase Closing Date. 

“Initial Advance CP Date” means the date on which the conditions precedent in Sections 4.2 (Conditions to Initial
Advance) and 4.4 (Conditions to Each Advance) of the Common Terms Agreement have been satisfied or waived in full, in accordance with the provisions in Section 4.5(a) (Satisfaction of Conditions) of the Common Terms Agreement.

  
 A-37 

 “Initial Corpus Christi Terminal Facility” means a liquefaction facility
comprised of two Trains, each with a nominal production capacity of approximately 4.5 mtpa, two LNG storage tanks, each with a working capacity of 160,000 cubic meters, and a marine berth), with related onsite and offsite utilities and supporting
infrastructure, as such facilities may be repaired and replaced from time to time or modified, changes or expanded as permitted in the Finance Documents. 

“Initial LNG Buyers” means Pertamina, Endesa, Iberdrola, Gas Natural Fenosa, Woodside and EDF. 

“Initial LNG SPAs” means the following LNG SPAs entered into between CCL and the Initial LNG Buyers on or before the Signing
Date: 
  

	 	(a)	the amended and restated LNG SPA between CCL and Pertamina, dated as of March 20, 2015; 

the LNG SPAs between CCL and Endesa, dated as of April 1, 2014 and dated April 7, 2014; 

the LNG SPA between CCL and Iberdrola, dated as of May 30, 2014; 

the LNG SPA between CCL and Gas Natural Fenosa, dated as of June 2, 2014; 

the LNG SPA between CCL and Woodside, dated as of June 30, 2014; and 

the EDF LNG SPA. 

“Initial Permitted Senior Debt Hedging Instrument” means each Permitted Senior Debt Hedging Instrument identified as such in
Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility
Office) to the Common Security and Account Agreement as of the Second Phase Closing Date. 
 “Initial Senior Creditor”
means each Senior Creditor under an Initial Senior Debt Instrument or an Initial Permitted Senior Debt Hedging Instrument as set forth in Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments /
Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office) to the Common Security and Account Agreement as of the Second Phase Closing Date. 

“Initial Senior Creditor Group Representative” means a Senior Creditor Group Representative that is a party to the Common
Terms Agreement as of the date of its execution and which is identified as such on Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior
Debt Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office) to the Common Security and Account Agreement. 

  
 A-38 

 “Initial Senior Debt” means the Senior Debt Obligations owing under the Term
Loan Facility Agreement, provided that for purposes of the definition of “Qualifying Term” under the Indenture, dated as of May 18, 2016, among Cheniere Corpus Christi Holdings, LLC, as Issuer, Corpus Christi Liquefaction, LLC,
Cheniere Corpus Christi Pipeline, L.P. and Corpus Christi Pipeline GP, LLC, as Guarantors and The Bank of New York Mellon, as Trustee, the reference to “Initial Senior Debt” shall mean the Senior Debt outstanding and committed under the
Initial Term Loan Facility Agreement. 
 “Initial Senior Debt Commitments” means the Senior Debt Commitments identified as
such in Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt Hedging Instruments, Addresses for Notice and Facility Lenders
Facility Office) to the Common Security and Account Agreement as of the Second Phase Closing Date. 
 “Initial Senior Debt
Instrument” means each Senior Debt Instrument identified as such in Schedule C (List of Senior Creditors, Senior Creditor Group Representatives, Senior Debt Commitments / Obligations, Senior Debt Instruments / Permitted Senior Debt
Hedging Instruments, Addresses for Notice and Facility Lenders Facility Office) to the Common Security and Account Agreement as of the Second Phase Closing Date. 

“Initial Senior Debt Obligations” means the Senior Debt Obligations under the Initial Senior Debt Instruments. 

“Initial Term Loan Facility Agreement” means the Term Loan Facility Agreement, dated as of May 13, 2015. 

“Initiating Percentage” means Senior Creditor Group Representatives representing the following percentages of the principal
amount of Senior Debt Obligations outstanding during the following periods (or, if no Senior Debt is outstanding, commitments in respect thereof): 
  

	 	i.	with respect to any Payment Default: 

  

	 	1.	at least 66.7% prior to 30 days following the occurrence of a Payment Default or the declaration thereof, as the case may be; 

  

	 	2.	greater than 50% on or after 30 days and prior to 120 days following the occurrence of a Payment Default or the declaration thereof, as the case may be; and 

	 	

	 	3.	the percentage held by any individual Senior Creditor Group, on or after 120 days following the occurrence of a Loan Facility Event of Default or an Indenture Event of Default (as applicable) or the declaration thereof,
as the case may be; and 

  
 A-39 

	 	ii.	with respect to any other Event of Default: 

  

	 	1.	at least 66.7% on or prior to 30 days following the occurrence of a Loan Facility Event of Default or an Indenture Event of Default (as applicable) or the declaration thereof, as the case may be; 

	 	

	 	2.	greater than 50% on or after 30 days and prior to 180 days following the occurrence of a Loan Facility Event of Default or an Indenture Event of Default (as applicable) or the declaration thereof, as the case may be;
and 

	 	

	 	3.	the percentage held by any individual Senior Creditor Group, on or after 180 days following the occurrence of a Loan Facility Event of Default or an Indenture Event of Default (as applicable) or the declaration thereof,
as the case may be. 

 “Insurance” shall mean (a) all insurance policies covering any or all of the
Collateral (regardless of whether the Security Trustee is the loss payee thereof) and (b) any key man life insurance policies. 

“Insurance Advisor” means Aon Risk Services or any independent replacement insurance consulting firm to be selected in
accordance with Section 13.2 (Replacement and Fees) of the Common Terms Agreement. 
 “Insurance/Condemnation Proceeds
Account” is the account described in Section 4.3(a)(ix) (Accounts) of the Common Security and Account Agreement. 

“Insurance Proceeds” means all proceeds of any insurance policies required pursuant to the Schedule of Minimum Insurance or
otherwise obtained with respect to the Development that are paid or payable to or for the account of the Loan Parties as loss payee (other than Business Interruption Insurance Proceeds and proceeds of insurance policies relating to third party
liability). 
 “Intellectual Property” means the collective reference to all rights, priorities and privileges relating to
intellectual property, whether arising under the United States, multinational or foreign laws or otherwise, including Copyrights, Copyright Licenses, Patents, Patent Licenses, Trademarks, Trademark Licenses, Trade Secrets, and Trade Secret Licenses,
and all rights to sue or otherwise recover for any past, present and future infringement, dilution, misappropriation, or other violation or impairment thereof, including the right to receive all proceeds therefrom, including license fees, royalties,
income, payments, claims, damages and proceeds of suit, now or hereafter due and/or payable with respect thereto. 

  
 A-40 

 “Intellectual Property Collateral” means any Intellectual Property which
constitutes Collateral, but only during the time that such Intellectual Property constitutes Collateral. 
 “Intercreditor
Agent” means the intercreditor agent appointed pursuant to the Intercreditor Agreement. 
 “Intercreditor
Agreement” means the Amended and Restated Intercreditor Agreement, dated as of the Second Phase Closing Date, among the Intercreditor Agent and each Senior Creditor Group Representative representing Facility Lenders and Hedging Banks,
setting forth the appointment of the Intercreditor Agent and setting forth voting and certain intercreditor arrangements among all Facility Lenders and Hedging Banks. 

“Interest Rate Hedging Instrument” means interest rate swaps, option contracts, futures contracts, options on futures
contracts, caps, floors, collars or any other similar arrangements entered into by the Borrower related to movements in interest rates. 

“International LNG Terminal Standards” means, to the extent not inconsistent with the express requirements of the Common Terms
Agreement, the international standards and practices applicable to the design, construction, equipment, operation or maintenance of LNG receiving, exporting, liquefaction and regasification terminals, established by the following (such standards to
apply in the following order of priority): (a) a Governmental Authority having jurisdiction over any Loan Party, (b) the Society of International Gas Tanker and Terminal Operators (“SIGTTO”) (or any successor body of the same)
and (c) any other internationally recognized non-governmental agency or organization with whose standards and practices it is customary for reasonable and prudent operators of LNG receiving, exporting,
liquefaction and regasification terminals to comply. In the event of a conflict between any of the priorities noted above, the priority with the alphabetical priority noted above shall prevail. 

“International LNG Vessel Standards” means, to the extent not inconsistent with the express requirements of the Common Terms
Agreement, the international standards and practices applicable to the ownership, design, equipment, operation or maintenance of LNG vessels established by: (a) the International Maritime Organization, (b) the Oil Companies International
Marine Forum, (c) SIGTTO (or any successor body of the same), (d) the International Navigation Association, (e) the International Association of Classification Societies, and (f) any other internationally recognized agency or non-governmental organization with whose standards and practices it is customary for reasonable and prudent operators of LNG vessels to comply. In the event of a conflict between any of the priorities noted above,
the priority with the alphabetical priority noted above shall prevail. 
 “Investment Company Act” means the United States
Investment Company Act of 1940. 
 “Investment Grade” means two long-term unsecured credit ratings that are equal to or
better than (a) Baa3 by Moody’s, (b) BBB- by S&P, (c) BBB- by Fitch, or (d) any comparable credit ratings by any other nationally recognized
statistical rating organizations. 

  
 A-41 

 “Investment Grade LNG Buyer” means an LNG Buyer that (a) is Investment
Grade, (b) has its obligations guaranteed by an Investment Grade entity or (c) for the purposes of LNG SPAs in Section 8.1(a) (LNG SPA Maintenance), Section 8.2(a)(i) (LNG SPA Mandatory Prepayment) or
Section 11.1 (Conditions to Restricted Payments) of the Common Terms Agreement, has all of its obligations under the applicable LNG SPA supported by a letter of credit issued by an Acceptable Bank. 

“Judgment Currency” has the meaning given in Section 12.3 (Judgment Currency) of the Common Security and Account
Agreement. 
 “Kinder Morgan” means Kinder Morgan Texas Pipeline LLC, a limited liability company organized under the laws
of the State of Delaware. 
 “Kinder Morgan Intrastate Firm Gas Transportation Agreement” means the firm gas transportation
agreement, dated as of September 19, 2014, between CCL, Kinder Morgan and Kinder Morgan Tejas, pursuant to which Kinder Morgan Tejas will transport certain quantities of Gas on its pipeline system within Texas. 

“Kinder Morgan Tejas” means Kinder Morgan Tejas Pipeline LLC, a limited liability company organized under the laws of
the State of Delaware. 
 “Knowledge” means, with respect to any of the Loan Parties, the actual knowledge of any Person
holding any of the positions (or successor position to any such position) set forth in Schedule T (Knowledge Parties) to the Common Terms Agreement; provided that each such Person shall be deemed to have knowledge of all events,
conditions and circumstances described in any notice delivered to the Borrower pursuant to the terms of the Common Terms Agreement or any other Finance Document. “Knowingly” shall have a corresponding meaning. 

“La Quinta Ship Channel Franchise” means the La Quinta Ship Channel Franchise, dated as of March 17, 2015, between Port
of Corpus Christi Authority of Nueces County, Texas and CCL. 
 “LC Costs” means (a) fees, expenses and interest
associated with Working Capital Debt and (b) any reimbursement by a Loan Party of amounts paid under a letter of credit that is Working Capital Debt for expenditures that if paid by such Loan Party directly would have constituted Operation and
Maintenance Expenses. 
 “Lenders” has the meaning given in 23.21 (No Fiduciary Duty) of the Common Terms Agreement.

 “Lenders’ Reliability Test” means each operational test described which in each case demonstrates that the Project
Facilities overall production during the applicable time periods can meet the applicable minimum cumulative LNG production sales volumes without exceeding a maximum amount of allowable downtime as set forth in Schedule O (Lenders’
Reliability Test Criteria) to the Common Terms Agreement. 

  
 A-42 

 “LIBOR” means, in respect of any Loan, if applicable, and in relation to any
Relevant Interest Period, the percentage rate per annum as determined by the applicable Facility Agent to be equal to: 
  

	 	(a)	the offered rate per annum for deposits in US Dollars which is quoted on the Screen Rate for the purpose of displaying London interbank offered rates of major banks for deposits in US Dollars as administered by ICE
Benchmark Administration Limited (or any other Person which takes over the administration of that rate) in US Dollars, (before any correction, recalculation or republication by the administration) for a period of six months or such other period that
corresponds to the Relevant Interest Period, at approximately 11:00 a.m. London time on the applicable quotation date; or 

if no such quotation so appears, and no other page is so agreed between the Borrower and the Intercreditor Agent at or about
such time, the arithmetic mean (rounded upwards, if necessary, to five decimal places) of the rates per annum for deposits in US Dollars for a period of six months or such other period that corresponds to the Relevant Interest Period (in each case
as supplied to the Intercreditor Agent at its request), at which rates at least three of the Reference Banks were offering to leading banks in the London interbank market, or as otherwise defined in the Facility Agreement; provided, in each
case, that if any such rate is below zero, LIBOR will be deemed to be zero. 
 “Lien” means any mortgage, pledge, lien,
charge, assignment, assignment by way of security, hypothecation or security interest securing any obligation of any Person, any restrictive covenant or condition, right reservation, right to occupy, encroachment, option, easement, servitude, right
of way or other imperfection of title or encumbrance (including matters that would be shown on an accurate survey) burdening any real property or any other agreement or arrangement having the effect of conferring security howsoever arising. 

“Lien Waiver” means a Lien waiver contemplated by the Applicable EPC Contracts. 

“LNG” means Gas in a liquid state at or below its boiling point at a pressure of approximately one atmosphere. 

“LNG Buyer” means the various buyers under the LNG SPAs entered into with CCL from time to time. 

“LNG SPA” means the sale and purchase agreements between CCL and various buyers of LNG pursuant to which CCL will sell and the
buyers will purchase LNG from CCL. 
 “LNG SPA Force Majeure” means “Force Majeure” as defined in each Initial LNG
SPA. 
 “LNG SPA Mandatory Prepayment” has the meaning given in Section 8.2(a) (LNG SPA Mandatory Prepayment) of
the Common Terms Agreement. 

  
 A-43 

 “LNG SPA Prepayment Event” has the meaning given in Section 8.2(a) (LNG
SPA Mandatory Prepayment) of the Common Terms Agreement. 
 “Loan Facility Declared Default” means a Loan Facility Event
of Default that is declared to be a default in accordance with Section 15.2 (Declaration of Loan Facility Declared Default) of the Common Terms Agreement. 

“Loan Facility Disbursement Accounts” are the Accounts described in Section 4.3(a)(i) (Accounts) of the Common
Security and Account Agreement. 
 “Loan Facility Event of Default” means any of the events set forth in Section 15.1
(Loan Facility Events of Default) of the Common Terms Agreement or any Loan Party events of default under any Facility Agreement. 

“Loan Parties” means, collectively, the Guarantors and the Borrower. The “Loan Parties” are also referred to as
“Securing Parties” in the Common Security and Account Agreement. 
 “Loans” means the Senior Debt Obligations
created under individual Facility Agreements to be made available by the Facility Lenders. 
 “Major Subcontractor” has the
meaning given in each Applicable EPC Contract. 
 “Major Sub-subcontractor” has the
meaning given in each Applicable EPC Contract. 
 “Majority in Interest of the Senior Creditors” with respect to any
Decision at any time means Senior Creditors: 
  

	 	(a)	whose share in the outstanding principal amount of the Senior Debt Obligations and whose undrawn Senior Debt Commitments are more than 50% of all of the outstanding principal amount of the Senior Debt Obligations and
all the undrawn Senior Debt Commitments of all the Senior Creditors; or 

 if there is no principal amount of
Senior Debt Obligations then outstanding, Senior Creditors whose Senior Debt Commitments are more than 50% of the aggregate Senior Debt Commitments of all Senior Creditors. 

“Management Services Agreements” mean the agreements between the Loan Parties and the Manager for their respective Project
Facilities. 
 “Manager” shall mean Cheniere Energy Shared Services, Inc. 

“Mandatory Prepayment Senior Notes Account” has the meaning given in Section 4.3(a)(x) (Accounts) of the Common
Security and Account Agreement. 
 “Margin Stock” means margin stock as defined in Regulation U of the Federal Reserve
Board. 

  
 A-44 

 “Market Consultant” means Wood Mackenzie Limited or any independent replacement
marketing consulting firm to be selected in accordance with Section 13.2 (Replacement and Fees) of the Common Terms Agreement. 

“Market Terms” means terms consistent with or more favorable to the applicable Loan Party (as seller or buyer, as the case may
be) than the terms a non-Affiliated seller or buyer, as the case may be, of the relevant product could receive in an arm’s-length transaction based on then-current
market conditions for transactions of a similar nature and duration and taking into account such factors as the characteristics of the goods and services, the market for such goods and services (including any applicable regulatory conditions), tax
effects of the transaction, the location of the Project Facilities and the counterparties. 
 “Material Adverse Effect”
means a material adverse effect on: 
  

	 	(a)	each Loan Party’s ability to perform and comply with its material obligations under each Material Project Agreement then in effect and to which it is a party; 

the Loan Parties’ ability, taken as a whole, to perform their material obligations under the Finance Documents; 

the Borrower’s ability to pay its Senior Debt Obligations when due; 

the Security Interests created by or under the relevant Security Documents, taken as a whole in respect of the Loan Parties
or the Development, as relevant including the material impairment of the rights of or benefits or remedies, taken as a whole, available to the Secured Parties; or 

the Loan Parties’ financial condition and results of operation, on a consolidated basis. 

“Material Project Agreements” means: 
  

	 	(a)	the Initial LNG SPAs in each case along with any related parent guarantees; 

the EPC Contract (T1/T2)), together with any related guarantees of the EPC Contractor’s obligations under each such EPC
Contract provided by the EPC Guarantors; 
 the Technology License Agreement (T1/T2); 

the Real Property Documents; 

the Management Services Agreements; 

the O&M Agreements; 

the CCP Pipeline Precedent Agreement; 

the CEI Equity Contribution Agreement; 

  
 A-45 

 the Gas and Power Supply Services Agreement; 

the CMI Export Authorization Letter; 

the Kinder Morgan Intrastate Firm Gas Transportation Agreement; 

the TGP Precedent Agreement; 

the La Quinta Ship Channel Franchise; 

the Construction Agreement for the Corpus Christi Pipeline Project, dated as of November 10, 2016, between CCP, as owner
and Associated Pipe Line Contractors, Inc., as contractor; 
 the Construction Agreement for the Corpus Christi Pipeline
Project, dated as of November 4, 2016, between CCP, as owner and Sunland Construction, Inc., as contractor; 
 the
Construction Agreement for the Corpus Christi Pipeline Project, dated as of November 3, 2016, between CCP, as owner and REF-CHEM, L.P., as contractor; 

the Precedent Agreement for Firm Transportation Service Under Gulf Connector Expansion Project, dated as of December 16,
2015, between CCL and Transcontinental Gas Pipe Line Company, LLC; 
 the Contractual Service Agreement, dated as of
October 21, 2015, between CCL and GE Oil & Gas, Inc.; 
 the Precedent Agreement, dated as of June 8,
2015 between CCL and Natural Gas Pipeline Company of America LLC; 
 the Natural Gas Pipeline Company of America LLC
(Natural) Transportation Rate Schedule FTS Agreement, dated as of September 24, 2015, between CCL and Natural Gas Pipeline Company of America LLC; 

the Gas Transportation Agreement, dated as of November 20, 2014, between CCL and Tennessee Gas Pipeline Company, L.L.C.;

 the Firm Transportation Negotiated Rate Agreement, dated as of November 20, 2014, between CCL and Tennessee Gas
Pipeline Company, L.L.C.; 
 the Service Agreement, dated as of December 19, 2017, between CCL and Transcontinental
Gas Pipe Line Company, LLC; 
 the Service Agreement, dated as of February 15, 2018, between CCL and CCP; 

the Negotiated Rate Letter Agreement, dated as of February 15, 2018, between CCL and CCP; 

  
 A-46 

 the Second Phase Material Project Agreements; and 

any Subsequent Material Project Agreement (upon a Loan Party becoming a party to such Subsequent Material Project Agreement).

 With respect to any Indenture, Material Project Agreements will have the meaning given in such Indenture. 

“Minimum Acceptance Criteria” has the meaning given in each Applicable EPC Contract. 

“Minimum Acceptance Criteria Correction Period” has the meaning given in each Applicable EPC Contract. 

“Minimum Insurance” means the insurance described in the Schedule of Minimum Insurance and required to be procured and
maintained pursuant to Section 12.28 (Insurance Covenant) of the Common Terms Agreement. 
 “MMBtu” means
1,000,000 Btus. 
 “Modification” means, with respect to any Finance Document, any amendment, supplement, waiver or other
modification of the terms and provisions thereof and the term “Modify” shall have a corresponding meaning; provided, that with respect to Sections 7.2(b)(ii)(A), (B) and (C) (Modification Approval Levels –
Modifications to Other Finance Documents) of the Common Security and Account Agreement, the exercise of any option, right or entitlement expressly set forth in the proviso to each such clause shall not be a Modification. 

“Moody’s” means Moody’s Investors Service, Inc. or any successor thereto. 

“Mortgaged Property” has the meaning given in Section 12.28 (Insurance Covenant) of the Common Terms Agreement.

 “mtpa” means million metric tonnes per annum. 

“Multiemployer Plan” means a “multiemployer plan” as in Section 3(37) of ERISA to which contributions have been
made by any Loan Party or any ERISA Affiliate in the past five years and which is covered by Title IV of ERISA. 
 “Natural Gas
Act” means the Natural Gas Act of 1938 and the regulations of FERC and DOE promulgated thereunder. 
 “Net Cash
Proceeds” means in connection with any asset disposition, the aggregate cash proceeds received by any Loan Party in respect of any asset disposition (including any cash received upon the sale or other disposition of any non-cash consideration received in any asset disposition), net of the direct costs and expenses relating to such asset disposition and payments made to retire Indebtedness (other than the Senior Debt Obligations)
required to be repaid in connection therewith, including legal, accounting 

  
 A-47 

 
and investment banking fees, and sales commissions, and any relocation expenses incurred as a result of such asset disposition, taxes paid or payable as a result of such asset disposition, in
each case, after taking into account any available tax credits or deductions and any tax sharing arrangements, and amounts reserved for adjustment in respect of the sale price of such asset or assets established in accordance with GAAP. 

“New Facility Agent Accession Agreement (Additional Senior Debt)” has the meaning given in Section 19.4(b)(i)
(Accession in the Event of Additional Senior Debt Incurred Under the Common Terms Agreement) of the Common Terms Agreement. 

“Non-Base Case Cash Flows” means the amount of all Cash Flows received from sales of
LNG made pursuant to LNG SPAs that are not Qualifying LNG SPAs minus the costs of purchasing, storing and transporting Gas attributable to such LNG sales. 

“Non-Base Case Restricted Payments” means Restricted Payments made with Non-Base Case Cash Flows pursuant to Section 11.3(b) (Additional Restricted Payments) of the Common Terms Agreement. 

“Non-Consenting Lender”, with respect to a Facility Agreement, has the meaning given
in such Facility Agreement. 
 “Non-Controlling Claimholders” means Senior Creditor
Group Representatives who were not included in the Majority in Interest of the Senior Creditors who make up the Controlling Claimholders. 

“Non-FTA Authorization” means the DOE/FE Order No. 3638, issued on May 12,
2015, granting CMI and CCL long-term, multi-contract Export Authorization to export LNG by vessel from the Corpus Christi Terminal Facility to nations with which the United States has not entered into free trade agreements providing for national
treatment for trade in natural gas. 
 “Non-Recourse Persons” has the meaning given
in Section 10.3(a) (Limitation on Recourse) of the Common Security and Account Agreement. 
 “Notice of Security
Enforcement Action” has the meaning given in Section 6.2(f) (Initiation of Security Enforcement Action – Notice of Security Enforcement Action) of the Common Security and Account Agreement. 

“Notice to Proceed” has the meaning given in each Applicable EPC Contract. 

“NYMEX” means the New York Mercantile Exchange, Inc., a wholly owned subsidiary of the CME Group Inc. 

“NYMEX Natural Gas Futures Contract” means the Futures Contract for natural gas on NYMEX, which is used for the physical
receipt and/or delivery of gas at the Henry Hub located in Erath, Louisiana. 

  
 A-48 

 “O&M Agreements” means the agreements between the Loan Parties and the
Operator for their respective Project Facilities. 
 “OFAC” means the Office of Foreign Assets Control of the US Department
of the Treasury. 
 “OFAC Laws” means any laws, regulations, and executive orders relating to the economic sanctions
programs administered by OFAC, including the International Emergency Economic Powers Act, 50 U.S.C. sections 1701 et seq.; the Trading with the Enemy Act, 50 App. U.S.C. sections 1 et seq.; and the Office of Foreign Assets Control, Department of the
Treasury Regulations, 31 C.F.R. Parts 500 et seq. (implementing the economic sanctions programs administered by OFAC). 
 “OFAC SDN
List” means the list of “Specially Designated Nationals and Blocked Persons” maintained by OFAC. 
 “Operating
Account” is the Account described in Section 4.3(a)(vi) (Accounts) of the Common Security and Account Agreement. 

“Operating Budget” has the meaning given in Section 10.5(a) (Operating Budget) of the Common Terms Agreement, it
being acknowledged and understood that the “Operating Budget” will be comprised of a budget in respect of the Corpus Christi Terminal Facility and a budget in respect of the Corpus Christi Pipeline and that all references in the Finance
Documents to the “Operating Budget” shall be to such budgets collectively or to the budget applicable to the Project Facilities that are the subject of the applicable provision, as the context may require. 

“Operating Manual” means the O&M Procedures Manual (as defined in the relevant O&M Agreement). 

“Operation and Maintenance Expenses” means, for any period, computed without duplication, in each case, costs and expenses of
the Loan Parties that are contemplated by the then-effective Operating Budget or are incurred in connection with any permitted excess thereunder pursuant to Section 12.3 (Project Construction; Maintenance of Properties) of the Common
Terms Agreement including: 
  

	 	(a)	fees and costs of the Manager pursuant to the Management Services Agreements; plus 

amounts payable by the Loan Parties under a Material Project Agreement then in effect; plus 

expenses for operating the Development and maintaining it in good repair and operating condition payable during such period,
including the ordinary course fees and costs of the Operator payable pursuant to the O&M Agreements and fees and costs payable pursuant to the Gas and Power Supply Services Agreement; plus 

LC Costs; plus 

  
 A-49 

 insurance costs payable during such period; plus 

applicable sales and excise taxes (if any) payable or reimbursable by the Loan Parties during such period; plus 

franchise taxes payable by the Loan Parties during such period; plus 

property taxes payable by the Loan Parties during such period; plus 

any other direct taxes (if any) payable by the Loan Parties to the taxing authority (other than any taxes imposed on or
measured by income or receipts) during such period; plus 
 costs and fees attendant to the obtaining and
maintaining in effect the Permits payable during such period; plus 
 expenses for spares and other capital goods
inventory, capital expenses related to the construction and start-up of the Project Facilities, maintenance capital expenditures, including those required to maintain the Project Facilities’ capacity;
plus 
 legal, accounting and other professional fees of the Loan Parties payable during such period; plus

 Required Capital Expenditures; plus 

the cost of purchase, storage and transportation of Gas and electricity; plus 

all other cash expenses payable by the Loan Parties in the ordinary course of business. 

Operation and Maintenance Expenses shall exclude, to the extent included above: (i) transfers from any Account into any other Account
(other than the Operating Account) during such period, (ii) payments of any kind with respect to Restricted Payments during such period, (iii) depreciation for such period, and (iv) except as provided in clauses (j), (k) and
(m) above, any capital expenditure. 
 To the extent amounts are advanced in accordance with the terms of the applicable Senior Debt
Instrument, secured Permitted Hedging Instrument or other Indebtedness permitted under Section 12.14 (Limitation on Indebtedness) of the Common Terms Agreement for the payment of such Operation and Maintenance Expenses, the obligation to
repay such advances shall itself constitute an Operation and Maintenance Expense. 
 “Operator” means Cheniere LNG O&M
Services, LLC, a limited liability company organized under the laws of the State of Delaware. 
 “Optimized Cascade Process”
has the meaning given in each Applicable EPC Contract. 

  
 A-50 

 “Other Approved LNG SPAs” means LNG SPAs between CCL and any LNG Buyer of
Supplemental Quantities as long as such LNG SPA has been approved by the Intercreditor Agent (acting on the instruction of Requisite Intercreditor Parties). 

“Other Connection Taxes” means, with respect to any Finance Party, Taxes imposed as a result of a present or former connection
between such Finance Party and the jurisdiction imposing such Tax (other than connections arising from such Finance Party having executed, delivered, become a party to, performed its obligations under, received payments under, received or perfected
a security interest under, sold or assigned an interest in, or engaged in any other transaction pursuant to or enforced any Finance Document). 

“Other Taxes” means all present or future stamp, court or documentary, intangible, recording, filing or similar Taxes that
arise from any payment made under, from the execution, delivery, performance, enforcement or registration of, from the receipt or perfection of a security interest under, or otherwise with respect to, any Finance Document (other than any Indenture
or Senior Notes), except any such Taxes that are Other Connection Taxes imposed with respect to an assignment of a Facility Lender’s interest in a Facility Agreement (other than an assignment made pursuant to Section 19.5 (Mitigation
Obligations; Replacement of Lenders) of the Common Terms Agreement). 
 “Participant” means each Person (other than a
natural Person, or a holding company, investment vehicle or trust for, or owned and operated for the primary benefit of, a natural Person) to whom a Facility Lender may sell participations from time to time. 

“Participant Register” means a register on which each Facility Lender which sells a participation, enters the name and address
of each Participant and the principal amounts (and stated interest) of each Participant’s interest in the relevant Facility Agreement or other obligations under the Finance Documents. Each Facility Lender that sells a participation shall,
acting solely for this purpose as a non-fiduciary agent of the Borrower, maintain a Participant Register. 

“Parties”, with respect to any agreement, means the signatories to such agreement. 

“Patent Licenses” means all agreements, licenses and covenants providing for the granting of any right in or to any Patent or
otherwise providing for a covenant not to sue for infringement or other violation of any Patent (whether a Loan Party is licensee or licensor thereunder) including each agreement required to be listed in Schedule J (Intellectual Property) to
the Common Security and Account Agreement under the heading “Patent Licenses” (as such schedule may be amended or supplemented from time to time). 

“Patents” means all United States and foreign and multinational patents and certificates of invention, or similar industrial
property rights, and applications for any of the foregoing, including: 

  
 A-51 

	 	(a)	each patent and patent application required to be listed in Schedule J (Intellectual Property) to the Common Security and Account Agreement under the heading “Patents” (as such schedule may be amended
or supplemented from time to time); 

 all reissues, substitutes, divisions, continuations, continuations-in-part, extensions, renewals, and reexaminations thereof; 

all inventions and improvements described and claimed therein; 

all rights to sue or otherwise recover for any past, present and future infringement or other violation thereof; 

all proceeds of the foregoing, including license fees, royalties, income, payments, claims, damages, and proceeds of suit now
or hereafter due and/or payable with respect thereto; and 
 all other rights of any kind accruing thereunder or pertaining
thereto throughout the world. 
 “Payment Date” means each CTA Payment Date and any other date for payment of Senior Debt
Obligations (including payment dates for the payment of interest) under or pursuant to any Senior Debt Instrument, including any Indenture, or Permitted Hedging Instrument. 

“Payment Default” means any event of default under Section 15.1(a) (Loan Facility Events of Default – Payment
Default) of the Common Terms Agreement and any comparable provision in any Senior Debt Instrument then in effect entered into after the date of the Common Security and Account Agreement. 

“PBGC” means the Pension Benefit Guaranty Corporation established pursuant to Subtitle A of Title IV of ERISA (or any
successor). 
 “PDE Senior Debt” has the meaning given in Section 6.4(a) (PDE Senior Debt) of the Common Terms
Agreement. 
 “Performance Guarantee” has the meaning given in each Applicable EPC Contract. 

“Performance Liquidated Damages” means any liquidated damages resulting from the Project Facilities’ performance that are
required to be paid by the EPC Contractor or any other counterparty to a Material Project Agreement for or on account of any diminution to the performance of the Project Facilities. 

“Performance Test” has the meaning given to such term in each Applicable EPC Contract. 

“Permit” means (a) any authorization, consent, approval, license, lease, ruling, tariff, rate, certification, waiver,
exemption, filing, variance, claim, order, judgment or decree of, by or with, (b) any required notice to, (c) any declaration of or with, or (d) any registration 

  
 A-52 

 
by or with, in the cases of the foregoing clauses (a) through (d), any Governmental Authority and then required for the development, construction and operation of the Project Facilities as
contemplated in the Finance Documents and the Material Project Agreements then in effect. 
 “Permitted Completion Amount”
means a sum equal to an amount certified by the Borrower (and confirmed reasonable by the Independent Engineer) on the Project Completion Date as necessary to pay 150% of the Permitted Completion Costs. 

“Permitted Completion Costs” means unpaid Project Costs (including Project Costs not included in the Construction Budget and
Schedule delivered on the Second Phase Closing Date) that the Borrower reasonably anticipates will be required for the Project Facilities to pay all remaining costs associated with outstanding Punchlist (as defined in each Applicable EPC Contract)
work, retainage, fuel incentive payments, disputed amounts (to the extent such disputed amounts have not been escrowed pursuant to Section 18.4 (Escrow of Certain Disputed Amounts By Owner) of an Applicable EPC Contract), and other costs
required under the Applicable EPC Contracts. 
 “Permitted Development Expenditures” means Development Expenditures that:

  

	 	(a)	are required by applicable law or regulations, any consent from a Governmental Authority, Industry Standards or Prudent Industry Practice applicable to the Development; or 

 

	 	(b)	are otherwise used for the Development; and 

 are funded from (i) Equity Funding not
otherwise committed to other expenditure for the Development, (ii) Insurance Proceeds and Condemnation Proceeds to the extent permitted by Article 5 (Insurance and Condemnation Proceeds and Performance Liquidated Damages) of the Common
Security and Account Agreement or proceeds of dispositions to the extent permitted by Section 12.17 (Sale of Project Property) of the Common Terms Agreement or any equivalent provision of any other Senior Debt Instrument,
(iii) Cash Flow permitted to be used for Operation and Maintenance Expenses (pursuant to clauses (c) and (k) of the definition thereof) or (iv) PDE Senior Debt in accordance with Section 6.4 (PDE Senior Debt) of the Common
Terms Agreement, Expansion Senior Debt in accordance with Section 6.5 (Expansion Senior Debt) of the Common Terms Agreement or other Indebtedness permitted to be incurred under Section 12.14 (Limitation on Indebtedness) of
the Common Terms Agreement, in the case of each of the foregoing sub-clauses (i), (ii) and (iv), in each case as expressly permitted under the Finance Documents and which use for the contemplated development
could not reasonably be expected to have a Material Adverse Effect. 
 “Permitted Finance Costs” means, for any period, the
sum of all amounts of principal, interest, fees and other amounts payable in relation to Indebtedness (other than Senior Debt and other than LC Costs and other amounts payable in relation to Indebtedness that constitute Operation and Maintenance
Expenses) permitted by Section 12.14(b) (Limitation on Indebtedness) (including guarantees thereof permitted under Section 12.15 

  
 A-53 

 
(Guarantees) of the Common Terms Agreement during such period) plus all amounts payable during such period pursuant to Permitted Hedging Instruments that are not secured, plus
any amounts required to be deposited in margin accounts pursuant to Permitted Hedging Instruments; provided that Permitted Finance Costs will not include funds categorized as Operation and Maintenance Expenses under the last sentence of
the definition thereof. 
 “Permitted Finance Costs Reserve Account” is the account described in Section 4.3(a)(xiii)
(Accounts) of the Common Security and Account Agreement. 
 “Permitted Hedging Instrument” means a Hedging Instrument
entered into by a Loan Party in the ordinary course of business and that (i) is with a Hedging Bank, a Gas Hedge Provider or a Power Hedge Provider, (ii) if secured, is of the type referred to in clause (a) or (b) of the definition of
Hedging Instrument and (iii) is entered for non-speculative purposes and is on arm’s-length terms; provided that (a) if such Hedging Instrument is
a Gas Hedging Instrument, it is for a period not to exceed the three prompt month contracts (or in the case of Basis Swaps, thirty six months) and the aggregate quantum under all (1) Futures Contracts, Fixed-Floating Futures Swaps, NYMEX
Natural Gas Futures Contracts and Swing Swaps does not exceed 50 TBtu, (2) Index Swaps does not exceed 23.25 TBtus, and (3) Basis Swaps does not exceed 23.25 TBtus, where the limitations in each of the categories described in sub-clauses (1), (2) and (3) are not aggregated, and (b) if such Hedging Instrument is a Power Hedging Instrument, the aggregate quantum under such Hedging Instrument does not exceed 3,650,000 megawatt
hours and each such Hedging Instrument is for a period not to exceed sixty months where the first month is the month in which the power hedging contract is executed. “Permitted Hedging Instrument” includes any “Permitted
Senior Debt Hedging Instrument.” 
 “Permitted Hedging Liabilities” means all present and future liabilities
(actual or contingent) payable or owing by a Loan Party under Permitted Hedging Instruments (including the obligation to pay a Hedging Termination Amount) together with: 
  

	 	(a)	any novation, deferral or extension of any of those liabilities; 

 any claim
for damages or restitution arising out of, by reference to or in connection with any of those liabilities; 
 any claim
flowing from any recovery by a Loan Party or a receiver or liquidator thereof or any other Person of a payment or discharge in respect of any of those liabilities on grounds of preference or otherwise; and 

any amounts (such as post-insolvency interest) which could be included in any of the above but for any discharge, non-provability, unenforceability or non-allowability of the same in any insolvency or other proceedings. 

“Permitted Liens” means: 
  

	 	(a)	Liens for taxes not delinquent or being contested in good faith and by appropriate proceedings in relation to which appropriate reserves are maintained and liens for customs duties that have been deferred in accordance
with the laws of any applicable jurisdiction; 

  
 A-54 

 deposits or pledges to secure obligations under workmen’s compensation,
old age pensions, social security or similar laws or under unemployment insurance; 
 deposits or other financial
assurances to secure bids, tenders, contracts (other than for borrowed money), leases, concessions, licenses, statutory obligations, surety and appeal bonds (including any bonds permitted under an EPC Contract), performance bonds and other
obligations of like nature arising in the ordinary course of business and cash deposits incurred in connection with natural gas purchases; 

mechanics’, workmen’s, materialmen’s, suppliers’, warehouse, Liens of lessors and sublessors or other
like Liens arising or created in the ordinary course of business with respect to obligations that are not due or that are being contested in good faith; 

(i) servitudes, easements, rights of way, encroachments and other similar encumbrances burdening the Development’s land
that are granted in the ordinary course, imperfections of title on real property, and restrictive covenants, zoning restrictions, licenses or conditions on the grant of real property (in relation to such real property); provided that such
servitudes, easements, rights of way, encroachments and other similar encumbrances, imperfections, restrictive covenants, restrictions, licenses or conditions do not materially interfere with the Development as contemplated in the Finance Documents
and the Material Project Agreements or have a material adverse effect on the Security Interests, and (ii) title exceptions disclosed by any title insurance commitment or title insurance policy delivered in accordance with the terms of the
Common Terms Agreement; 
 Liens to secure indebtedness permitted by Sections 12.14(g) and (o) (Limitation on
Indebtedness) of the Common Terms Agreement; 
 the Security Interests; 

Liens in the ordinary course of business arising from or created by operation of applicable law or required in order to
comply with any applicable law and that could not reasonably be expected to cause a Material Adverse Effect or materially impair the Development’s use of the encumbered assets; 

Liens in the ordinary course of business over any assets (the aggregate value of which assets at the time any such Lien is
granted does not exceed $25 million) that could not reasonably be expected to cause a Material Adverse Effect or materially impair the Development’s use of the encumbered assets; 

contractual or statutory rights of set-off (including netting) granted to the Loan
Parties’ bankers, under any Permitted Hedging Instrument or any Material Project Agreement and that could not reasonably be expected to cause a Material Adverse Effect; 

  
 A-55 

 deposits or other financial assurances to secure reimbursement or
indemnification obligations in respect of letters of credit or in respect of letters of credit put in place by a Loan Party and payable to suppliers, service providers, insurers or landlords in the ordinary course of business; 

Liens that are scheduled exceptions to the coverage afforded by a Title Policy on the Second Phase Closing Date or later date
of amendment of a Title Policy or delivery of a new Title Policy; 
 legal or equitable encumbrances (other than any
attachment prior to judgment, judgment lien or attachment in aid of execution on a judgment) deemed to exist by reason of the existence of any pending litigation or other legal proceeding if the same is effectively stayed or the claims secured
thereby are being contested in good faith and by appropriate proceedings and an appropriate reserve has been established in respect thereof in accordance with GAAP; 

the Liens created pursuant to the Real Property Documents; 

Liens by any Loan Party in favor of any other Loan Party; and 

Liens arising out of judgments or awards not constituting an Event of Default so long as an appeal or proceeding for review
is being prosecuted in good faith and for the payment of which adequate cash reserves, bonds or other cash equivalent security have been provided or are fully covered by insurance (other than any customary deductible). 

“Permitted Payments” means, without duplication as to amounts allowed to be distributed under any other provision of the
Common Terms Agreement: 
  

	 	(a)	payments to an Affiliate of the Borrower to permit such Affiliate to pay its reasonable accounting, legal and administrative expenses when due, in an aggregate amount not to exceed $5 million per calendar year; and

 the amount necessary for payment to an Affiliate of the Borrower to enable it to pay its (or for such
Affiliate to satisfy any contractual obligation to distribute to its beneficial owners to enable them to pay their) income tax liability with respect to income generated by the Loan Parties, determined at the highest combined US federal and State of
Texas tax rate applicable to an entity taxable as a corporation in both jurisdictions for the applicable period. 
 “Permitted Senior
Debt Hedging Instrument” means a Permitted Hedging Instrument pursuant to sub-clause (ii) of the definition thereof that is secured by and benefits from the Common Security and Account Agreement.

  
 A-56 

 “Permitted Senior Debt Hedging Liabilities” means all present and future
liabilities (actual or contingent) payable or owing by a Loan Party under Permitted Senior Debt Hedging Instruments (including the obligation to pay a Senior Debt Hedging Termination Amount) together with: 

 

	 	(a)	any novation, deferral or extension of any of those liabilities; 

 any claim
for damages or restitution arising out of, by reference to or in connection with any of those liabilities; 
 any claim
flowing from any recovery by a Loan Party or a receiver or liquidator thereof or any other Person of a payment or discharge in respect of any of those liabilities on grounds of preference or otherwise; and 

any amounts (such as post-insolvency interest) which would be included in any of the above but for any discharge, non-provability, unenforceability or non-allowability of the same in any insolvency or other proceedings. 

“Person” means any individual, firm, corporation, partnership, joint venture, association, trust, unincorporated organization,
government agency, government or political subdivision thereof or other entity whether enjoying legal personality or not, and includes its successors or permitted assignees. 

“Pertamina” means PT Pertamina (Persero), an Indonesian state-owned energy company that is an Initial LNG Buyer. 

“PetroChina” means PetroChina International Company Limited, a Chinese state-owned energy company that is an LNG Buyer. 

“PetroChina DES LNG SPA” means the LNG sale and purchase agreement, dated as of February 8, 2018, between PetroChina and
CMI (UK). 
 “PetroChina Direct Agreements” means (a) a Direct Agreement, between PetroChina, CCL, the Security Trustee
and CMI (UK), with respect to the PetroChina DES LNG SPA and (b) a Direct Agreement, between PetroChina Guarantor, CCL, the Security Trustee and CMI (UK), with respect to the parent guarantee provided in relation to the PetroChina DES LNG SPA,
in each case, in the form attached to the PetroChina DES LNG SPA delivered to the Intercreditor Agent in connection with the Second Phase Closing Date. 

“PetroChina FOB LNG SPA” means the LNG sale and purchase agreement, dated as of February 8, 2018, between PetroChina and
CCL. 
 “PetroChina Guarantor” means the guarantor of PetroChina’s obligations under the PetroChina FOB LNG SPA and/or
the PetroChina DES LNG SPA, as applicable, in accordance with the terms of the PetroChina FOB LNG SPA and the PetroChina DES LNG SPA, as applicable. 

  
 A-57 

 “Plan” means any “employee benefit plan” as defined in
Section 3(3) of ERISA, including any “employee welfare benefit plan” (as defined in Section 3(1) of ERISA) and/or any “employee pension benefit plan” (as defined in Section 3(2) of ERISA), that is or was maintained
or contributed to by any Loan Party or any ERISA Affiliate. 
 “Pledged Collateral” has the meaning given in
Section 3.2(a) (Security Interests to be Granted by the Securing Parties – Pledge of Pledged Collateral) of the Common Security and Account Agreement. 

“Pledged Debt Securities” has the meaning given in Section 3.2(a)(vii) (Security Interests to be Granted by the
Securing Parties – Pledge of Pledged Collateral) of the Common Security and Account Agreement. 
 “Pledged Equity
Interests” has the meaning given in Section 3.2(a)(i) (Security Interests to be Granted by the Securing Parties – Pledge of Pledged Collateral) of the Common Security and Account Agreement. 

“Power Hedge Provider” means any party (other than the Loan Parties or their Affiliates) that is a party to a Power Hedging
Instrument that is secured pursuant to the Security Documents. 
 “Power Hedging Instruments” means electricity swaps,
options contracts, futures contracts, options on futures contracts, caps, floors, collars or any other similar arrangements entered into by any Loan Party related to movements in electricity prices. 

“Pro Rata Payment” means, in respect of the Senior Debt Obligations, a payment to a Senior Creditor on any date on which a
payment of Senior Debt Obligations is made in which: 
  

	 	(a)	the amount of interest paid to such Senior Creditor on such date bears the same proportion to the total amount of interest payments made to all Senior Creditors on such date as (i) the total amount of Senior Debt
Obligations for interest due to such Senior Creditor on such date bears to (ii) the total amount of Senior Debt Obligations for interest due to all Senior Creditors on such date; 

the amount of principal paid to such Senior Creditor on such date bears the same proportion to the total amount of principal
payments made to all Senior Creditors on such date as (i) the total amount of Senior Debt Obligations for principal due to such Senior Creditor on such date bears to (ii) the total amount of Senior Debt Obligations for principal due to all
Senior Creditors on such date, in each case not including any principal payable by way of an acceleration of principal unless each Senior Debt Obligation has been accelerated; and 

fees, commissions, indemnities and all amounts other than interest and principal paid to such Senior Creditor on such date
bears the same proportion to the total fees, commissions, indemnities and such other amounts paid to all Senior Creditors on such date as (i) the total Senior Debt Obligations for fees, commissions, indemnities and such other amounts due to
such Senior Creditor on such date bears to (ii) the total Senior Debt Obligations for fees, commissions, indemnities and such other amounts due to all Senior Creditors on such date. 

  
 A-58 

 If payments cannot be made exactly in such proportion due to minimum required payment amounts and
required integral multiples of payments under Senior Debt Instruments, payments made in amounts as near such exactly proportionate amounts as possible shall be deemed to be Pro Rata Payments. 

“Project Completion Date” means the date upon which all of the conditions set forth in Section 14.1 (Conditions to
Occurrence of the Project Completion Date) of the Common Terms Agreement have been either satisfied, or, in each case, waived by the Requisite Intercreditor Parties. 

“Project Costs” means all costs of acquiring, leasing, designing, engineering, developing, permitting, insuring, financing
(including closing costs, other fees and expenses, commissions and discounts payable to any purchaser or underwriter of Senior Notes (to the extent such costs are paid from the proceeds of such Senior Notes), insurance costs (including premiums) and
interest and interest rate hedge expenses and Secured Party Fees), constructing, installing, commissioning, testing and starting-up (including costs relating to all equipment, materials, spare parts and labor
for) the Project Facilities (including the Second Phase Facilities), funding the Senior Debt Service Reserve Account and all other costs incurred with respect to the Development (including the Second Phase Development) in accordance with the
Construction Budget and Schedule, including working capital prior to the end of the Term Loan Availability Period, gas purchase, transport and storage costs and pre-Project Completion Date Operation and
Maintenance Expenses; provided that Project Costs will exclude any Operation and Maintenance Expenses (other than the portion thereof that is Required Capital Expenditure) for any Train of the Development if the LNG SPA related to such Train
has achieved Date of First Commercial Delivery pursuant to the terms of such LNG SPA. On any date on which a determination is being made whether specific sources of funding available to the Loan Parties are sufficient for the Development to achieve
the Project Completion Date by the Date Certain, the Project Costs against which the applicable sources of funding are measured to make this determination will be the remaining Project Costs required to be spent in order to achieve the Project
Completion Date as determined as of such determination date based on the then-current Construction Budget and Schedule, including in the case of commissioning costs determined on a net basis consistent with the then-current Construction Budget and
Schedule. 
 “Project Facilities” means the Corpus Christi Terminal Facility and the Corpus Christi Pipeline, as such
facilities may be repaired and replaced from time to time or modified, changed or expanded as permitted in the Finance Documents. 

“Project Property” means, at any point in time, all Project Facilities, material licenses in respect of the Development,
information, data, results (technical, economic, business or otherwise) known and other information that was developed or acquired as a result of Development operations. 

  
 A-59 

 “Prudent Industry Practice” means, at a particular time, any of the practices,
methods, standards and procedures (including those engaged in or approved by a material portion of the LNG industry) that, at that time, in the exercise of reasonable judgment in light of the facts known at the time a decision was made, could
reasonably have been expected to accomplish the desired result consistent with good business practices, including due consideration of the Development’s reliability, environmental compliance, economy, safety and expedition, and which practices,
methods, standards and acts generally conform to International LNG Terminal Standards and International LNG Vessel Standards, and solely with respect to Section 12.27 (Gas Transportation Arrangements; Gas Purchase Arrangements) of the
Common Terms Agreement and the definition of “Qualified Gas Supplier”, the standard industry practice applicable to the gas supply industry, including providing due consideration of the need for reliable supply and taking into account the
credit quality, track record and experience of suppliers, diversity of supply sources, quality of gas supplied and prudent contracting strategy in order to enable the Development to receive the quantum of natural gas required from time to time to
meet the obligations of the Loan Parties under the LNG SPAs. 
 “PUHCA” means the Public Utility Holding Company Act
of 2005 and FERC’s implementing regulations. 
 “Qualified ECP Party” means, in respect of any Swap
Obligation, each Loan Party that has total assets exceeding $10 million at the time the relevant guaranty or grant of the relevant security interest becomes effective with respect to such Swap Obligation or such other person as constitutes an
“eligible contract participant” under the Commodity Exchange Act or any regulations promulgated thereunder and can cause another person to qualify as an “eligible contract participant” at such time by entering into a keepwell
under Section 1a(18)(A)(v)(II) of the Commodity Exchange Act. 
 “Qualified Gas Supplier” means suppliers
of Gas reasonably selected from time to time by the Borrower in accordance with Prudent Industry Practice, including the suppliers listed on Exhibit A to the Gas Sourcing Plan, as updated semi-annually. 

“Qualified Transporter” means any Person possessing the requisite FERC Permit or requisite Texas Railroad
Commission permit to transport Gas. 
 “Qualifying LNG SPA” has the meaning given in Section 8.1(b) (LNG SPA
Maintenance) of the Common Terms Agreement. Qualifying LNG SPAs include the Initial LNG SPAs and the Second Phase LNG SPAs. 

“Qualifying Term” means (a) with respect to any new LNG SPA that meets the conditions to be, or is approved as, a
Qualifying LNG SPA, the term of such LNG SPA used in the Base Case Forecast when determining the quantum of Senior Debt to be incurred based on the revenues projected to be generated under such LNG SPA and (b) with respect to any LNG SPA
replacing a Qualifying LNG SPA, a term at least as long as the remaining term of the Qualifying LNG SPA it is replacing. 

  
 A-60 

 “Quarterly Payment Date” means each March 31, June 30,
September 30 and December 31. 
 “Ready for Performance Testing” has the meaning given in each Applicable EPC Contract.

 “Ready for Start Up” has the meaning given in each Applicable EPC Contract. 

“Real Estate” means all real property leases and all land, together with the buildings, structures, parking areas, and other
improvements thereon, now or hereafter owned by a Securing Party, including all easements, rights-of-way, and similar rights relating thereto and all leases, tenancies,
and occupancies thereof. 
 “Real Property Documents” means, at any time, the documents evidencing the Real Estate owned by
the Securing Parties. As of the Second Phase Closing Date, such documents are set forth on Schedule U (Real Property Documents) to the Common Terms Agreement. 

“Reasonable Commercial Terms” has the meaning given in Section 12.28(a) (Insurance Covenant) of the Common Terms
Agreement. 
 “Receivable” means all Accounts (as defined in the UCC) and any other right to payment for goods or other
property sold, leased, licensed or otherwise disposed of or for services rendered, whether or not such right is evidenced by an Instrument or Chattel Paper or classified as a Payment Intangible (each as defined in the UCC) and whether or not it has
been earned by performance. References herein to Receivables shall include any Supporting Obligation (as defined in the UCC) or collateral securing such Receivable. 

“Receiver” means an administrator, a receiver or receiver and manager, or, where permitted by law, an administrative receiver
or equivalent officer or person in a relevant jurisdiction of the whole or any part of the Collateral. 
 “Reference Banks”
means the principal London offices of each of JPMorgan Chase Bank, N.A. and Société Générale, or any other bank or financial institution as shall be specified by the Intercreditor Agent and approved by the Borrower (such
approval not to be unreasonably withheld). 
 “Register” has the meaning given in Section 19.7 (Register) of the
Common Terms Agreement. 
 “Related Parties” means, with respect to any specified Person, such Person’s Affiliates and
the respective shareholders, members, partners, directors, officers, employees and agents of such Person and such Person’s Affiliates. 

“Release” means, with respect to any Hazardous Material, any release, spill, emission, leaking, pouring, emptying, escaping,
dumping, pumping, injection, deposit, disposal, discharge, dispersal, leaching or migration of such Hazardous Material into the environment, including the movement of such Hazardous Material through ambient air, soil, surface water, ground water,
wetlands, land or subsurface strata. 

  
 A-61 

 “Relevant Interest Period” means, with respect to each Loan, the “Interest
Period” and/or “Interest Payment Period”, as applicable, as defined in the relevant Facility Agreement. 
 “Repeated
Representations” means the representations and warranties described in Section 5.2 (Repeated Representations and Warranties of the Loan Parties) of the Common Terms Agreement. 

“Replacement Debt Incremental Amounts” means the amount of Senior Debt Obligations under Replacement Senior Debt related to
the incurrence of such Replacement Senior Debt that are incremental to the Senior Debt Obligations that would have arisen under the replaced Senior Debt, including incremental interest payable on such Replacement Senior Debt compared to the replaced
Senior Debt and the amount of Replacement Senior Debt incurred to pay fees, provisions, costs, expenses and premiums associated with the incurrence of such Replacement Senior Debt. 

“Replacement Facility Agent Accession Agreement” has the meaning given in Section 19.3(b)(ii) (Replacement of Facility
Agents) of the Common Terms Agreement. 
 “Replacement Senior Debt” has the meaning given in Section 6.3(a)
(Replacement Senior Debt) of the Common Terms Agreement. 
 “Required Capital Expenditures” means capital
expenditures required to meet the requirements of any applicable laws and regulations, Permits (or interpretations thereof), or insurance policies, Industry Standards, and Prudent Industry Practice with which the Loan Parties are obligated to comply
under any Material Project Agreement and any other material agreements of the Loan Parties relating to the Development, including those relating to the environment. 

“Required Export Authorization” means, with respect to a Qualifying LNG SPA at any time, (a) the Non-FTA Authorization and (b) the FTA Authorization to the extent that (i) at such time, the volumes permitted to be exported under the FTA Authorization or the
Non-FTA Authorization, as the case may be, are required in order to enable the sale of such Qualifying LNG SPA’s share of the then-applicable Base Committed Quantity of LNG in accordance with the terms of
such Qualifying LNG SPA and (ii) an objection has not been received in respect of the identification of such Export Authorization as being (or not being) a “Required Export Authorization” pursuant to Section 8.1(b)(iv) (LNG
SPA Maintenance) of the Common Terms Agreement. For the avoidance of doubt, the Non-FTA Authorization is a Required Export Authorization for each of the Initial LNG SPAs in effect on the Second Phase
Closing Date and until otherwise determined in accordance with Section 8.2(a)(ii) (LNG SPA Mandatory Prepayment) of the Common Terms Agreement. 

“Required Intercreditor Parties” has the meaning given in Section 1.1 (Definitions) of the Intercreditor
Agreement. 

  
 A-62 

 “Required LNG SPA” means, at any time, the Qualifying LNG SPAs required to be
maintained pursuant to Section 8.1(a) (LNG SPA Covenants – LNG SPA Maintenance) of the Common Terms Agreement at such time. 

“Requisite Secured Parties” means the requisite percentage of Senior Creditors required under the Common Security and Account
Agreement with respect to a specific Decision in order to make such Decision and provide the required instruction to the Security Trustee. 

“Requisite Intercreditor Parties” has the meaning given in Section 1.1 (Definitions) of the Intercreditor
Agreement. 
 “Reservations” means the principle that equitable remedies are remedies which may be granted or refused at the
discretion of the court, the limitation of enforcement by laws relating to bankruptcy, insolvency, liquidation, re-organization, court schemes, moratorium, administration and other laws generally affecting the
rights of creditors, the time barring of claims under any legislation relating to limitation of claims, the possibility that an undertaking to assume liability for or to indemnify a Person against non-payment
of stamp duty may be void, defenses of set-off or counterclaim and similar principles, in each case both under New York law and the laws of other applicable jurisdictions and such other qualifications as to
matters of law as are contained in the legal opinions provided to the Senior Creditors pursuant to Section 4.1 (Conditions to Second Phase Closing) of the Common Terms Agreement. 

“Reserve Amount” means as of any date on and after the Project Completion Date, an amount necessary to pay Senior Debt
Obligations projected to be due and payable in the next two (in the case of quarterly Payment Dates) or one (in the case of semi-annual Payment Dates) Payment Dates (which shall, if not already included, include the Final Maturity Date under any
Senior Debt) (assuming that no Event of Default will occur during such period) taking into account, with respect to interest, the amount of interest that would accrue on the aggregate principal amount of Senior Debt outstanding for the covered six
month period and only such interest amount after giving effect to any Permitted Hedging Instrument in respect of interest rates then in effect; provided that (a) the Senior Debt Obligations projected to be due and payable for purposes of
this calculation shall not include (i) Working Capital Debt; (ii) any voluntary or mandatory prepayment; (iii) commitment fees, front end fees and letter of credit fees; or (iv) Hedging Termination Amounts; and (b) for
purposes of the calculation of the scheduled principal payments of the Senior Debt, any final balloon payment of Senior Debt shall not be taken into account and instead only the equivalent of the principal payment on the immediately preceding
Payment Date for payment of principal prior to such balloon payment shall be taken into account. 
 “Restricted Document”
has the meaning given in Section 12.6(c) (Confidentiality) of the Common Security and Account Agreement. 
 “Restricted
Operation and Maintenance Expenses” means Operation and Maintenance Expenses that do not constitute capital expenditures other than Required Capital Expenditures and those expenditures essential to construct the Project Facilities or to
maintain the Project Facilities’ capacity at, or to prevent a material increase in operating expenses from, the operating levels then in effect. 

  
 A-63 

 “Restricted Payment” means (a) any dividend or other distribution by the
Borrower (in cash, property of the Borrower, securities, obligations, or other property) on, or other dividends or distributions on account of, or the setting apart of money for a sinking or other analogous fund for, or the purchase, redemption,
retirement or other acquisition by the Borrower of, any portion of any membership interest in the Borrower and (b) all payments (in cash, property of the Borrower, securities, obligations, or other property) of principal of, interest on and
other amounts with respect to, or other payments on account of, or the setting apart of money for a sinking or other analogous fund for, or the purchase, redemption, retirement or other acquisition by the Borrower of, any Indebtedness owed to Holdco
or any other Person party to a pledge agreement or any Affiliate thereof, including any Subordinated Debt. Restricted Payments shall not include payments to the Manager for fees and costs pursuant to Management Services Agreements and fees and costs
payable pursuant to the Gas and Power Supply Services Agreement and payments to the Operator pursuant to the O&M Agreements (which shall be paid in accordance with Section 4.7 (Cash Waterfall) of the Common Security and Account
Agreement); Permitted Payments (which shall be paid in accordance with Section 4.7 (Cash Waterfall) of the Common Security and Account Agreement); amounts paid in accordance with Section 2.7 (Senior Debt/Equity Ratio at Project
Completion Date) of the Common Terms Agreement; and any of the payments in (a) or (b) above (whether in cash, securities, obligations or otherwise) made among any of the Loan Parties. 

“Revenue Account” is the account described in Section 4.3(a)(v) (Accounts) of the Common Security and
Account Agreement. 
 “Rolling Stock” means any motor vehicles, tractors, trailers and other like property, whether or not
the title thereto is governed by a certificate of title or ownership and other rolling stock, including such property for which the title thereto is evidenced by a certificate of title issued by the United States or a state that permits or requires
a lien thereon to be evidenced upon such title. 
 “S&P” means Standard & Poor’s Ratings Services, a
division of McGraw-Hill Financial, Inc., or any successor thereto. 
 “Sanctions Violation” has the meaning given in
Section 12.6(d) (Compliance with Law) of the Common Terms Agreement. 
 “Schedule Bonus” has the meaning given
in each Applicable EPC Contract. 
 “Schedule Bonus Date” has the meaning given in each Applicable EPC Contract. 

“Schedule of Minimum Insurance” has the meaning given in Section 12.28(a) (Insurance Covenant) of the Common Terms
Agreement. 

  
 A-64 

 “Screen Rate” means Reuters Page LIBOR01 (or if such page is not accessible or
ceases to display, such other page on the Reuters Screen or on the relevant pages of such other service as may be selected by the Intercreditor Agent for purposes of displaying comparable rates). 

“Second Phase Closing” means the satisfaction or waiver of all the conditions precedent set forth in Section 4.1
(Conditions to Second Phase Closing) of the Common Terms Agreement. 
 “Second Phase Closing Date” means the date on
which the conditions precedent set forth in Section 4.1 (Conditions to Second Phase Closing) of the Common Terms Agreement have been satisfied or waived. 

“Second Phase Development” means the development, acquisition, ownership, occupation, construction, equipping, testing,
repair, operation, maintenance and use of the Second Phase Facilities and the purchase, storage and sale of Gas and the storage and sale of LNG, the export of LNG from the Second Phase Facilities (and, if the Borrower so elects, the import of LNG to
the extent any Loan Party has all necessary Permits therefor), the transportation of Gas to the Second Phase Facilities by third parties, and the sale of other services or other products or by-products of the
Second Phase Facilities and all activities incidental thereto, in each case in accordance with the Transaction Documents. 
 “Second
Phase Facilities” means one liquefaction Train, with a nominal production capacity of approximately 4.5 mtpa, one LNG storage tank, with a working capacity of 160,000 cubic meters, one marine berth and certain onsite and offsite utilities
and supporting infrastructure, as such facilities may be improved, replaced, modified, changed or expanded in accordance with the Finance Documents. 

“Second Phase Finance Documents” means: 
  

	 	(a)	the Common Terms Agreement; 

 the Common Security and Account Agreement; 

the Term Loan Facility Agreement; 

any Security Documents required by the financing of the Second Phase Development; 

the Direct Agreements in respect of the Second Phase Material Project Agreements to the extent such Direct Agreement is
required to be delivered pursuant to Section 3.4 (Direct Agreements) of the Common Security and Account Agreement; 

the Intercreditor Agreement; 

the PetroChina Direct Agreements; and 

  
 A-65 

 any fee letters with parties providing financing (other than any Equity
Funding) in connection with the financing of the Second Phase Development. 
 “Second Phase LNG SPAs” means: 

 

	 	(b)	the Trafigura LNG SPA; 

 the PetroChina FOB LNG SPA; 

the DES-Linked LNG SPA; and 

the EDP LNG SPA. 
 “Second
Phase Material Project Agreements” means: 
  

	 	(a)	the Second Phase LNG SPAs in each case along with any related parent guarantees; 

the EPC Contract (T3), together with any related guarantees of the EPC Contractor’s obligations under such EPC Contract
provided by the EPC Guarantors; 
 the Technology License Agreement (T3); 

the CEI Equity Contribution Agreement; 

the Precedent Agreement, dated as of February 20, 2018, between CCL and Natural Gas Pipeline Company of America LLC;

 the Targa Gas Supply Agreement; and 

CMI Security Agreement. 

“Secured Accounts” means the Accounts and any escrow account established under the EPC Contracts (and, in each case, all cash
and Authorized Investments therein) subject to a Security Interest in favor of the Security Trustee on behalf of the Senior Creditors, excluding the Excluded Unsecured Accounts. 

“Secured Parties” means the Senior Creditors, the Senior Creditor Group Representatives, the Intercreditor Agent, the Security
Trustee and the Account Bank. 
 “Secured Party Fees” means any fees, costs, indemnities, charges, disbursements,
liabilities and expenses (including reasonably incurred legal fees and expenses) and all other amounts payable to the Security Trustee, the Intercreditor Agent, the Indenture Trustee or the Account Bank, as applicable, or any of their respective
agents and to any Senior Creditor Group Representative. 
 “Securing Parties” means, collectively, the Guarantors and the
Borrower. The “Securing Parties” are also referred to as “Loan Parties” in the Common Terms Agreement and certain Finance Documents. 

  
 A-66 

 “Securities Act” means the Securities Act of 1933. 

“Security Documents” means the Common Security and Account Agreement and any other document, agreement, notice, mortgage,
instrument or filing creating and/or perfecting any Lien required to be created or perfected by the Common Security and Account Agreement or any other Finance Document and shall include the Holdco Pledge Agreement, any deed of trust or mortgage
entered into pursuant to Section 3.2(f) (Security Interests to be Granted by the Securing Parties – Real Property) of the Common Security and Account Agreement and any Patent or Trademark security agreement entered into
pursuant to Section 3.5(g) (Perfection and Maintenance of Security Interest – Intellectual Property Recording Requirements) of the Common Security and Account Agreement. 

“Security Enforcement Action” means the exercise by the Security Trustee (or at its direction), following initiation of
enforcement action in compliance with Section 6.2 (Initiation of Security Enforcement Action) and Section 6.3 (Conduct of Security Enforcement Action) of the Common Security and Account Agreement, of enforcement rights with
respect to the Collateral and any of the other enforcement rights (including exercising step-in and other rights with respect to the Direct Agreements entered into pursuant to Section 3.4 (Direct
Agreements) of the Common Security and Account Agreement) contemplated by the Common Security and Account Agreement, the other Security Documents and the Direct Agreements. For the avoidance of doubt, Security Enforcement Action shall not
include any action taken by the Security Trustee (or at its direction) in accordance with Section 6.1 (Security Trustee Action Generally) of the Common Security and Account Agreement. 

“Security Enforcement Action Initiation Request” has the meaning given in Section 6.2(a) (Initiation of Security
Enforcement Action) of the Common Security and Account Agreement. 
 “Security Enforcement Action Representative” shall
mean, at any time, a Senior Creditor Group Representative, or a group of Senior Creditor Group Representatives acting together, that represents a Majority in Interest of the Senior Creditors (for purposes of this definition only, the
“Majority Representative”); provided that: 
  

	 	(a)	for so long as at least 20% of the outstanding principal amount of the Senior Debt Obligations is held by Facility Lenders, the Security Enforcement Action Representative shall be a Senior Creditor Group Representative,
or a group of Senior Creditor Group Representatives acting together, that represents a Majority in Interest of the Senior Creditors which includes Facility Lenders holding a majority of the outstanding principal amount of the Senior Debt Obligations
held by Facility Lenders; 

 if there is no principal amount of Senior Debt Obligations then outstanding and
at least 20% of the aggregate Senior Debt Commitments are held by Facility Lenders, the Security Enforcement Action Representative shall be a Senior Creditor Group Representative, or a group of Senior Creditor Group Representatives acting together,
that represents a Majority in Interest of the Senior Creditors which includes Facility Lenders holding a majority of the aggregate Senior Debt Commitments held by Facility Lenders; and 

  
 A-67 

 the Initiating Percentage shall be deemed to be the Security Enforcement Action
Representative if and only for so long as the Majority Representative (or the Security Enforcement Action Representative as determined pursuant to clause (a) or (b) above) is not diligently pursuing a Security Enforcement Action unless stayed
or otherwise precluded from doing so by law, regulation or order, in which case the Majority Representative (or the Security Enforcement Action Representative as determined pursuant to clause (a) or (b) above) shall remain the Security
Enforcement Action Representative until the Majority Representative (or the Security Enforcement Action Representative as determined pursuant to clause (a) or (b) above) is no longer stayed or otherwise precluded from diligently pursuing a
Security Enforcement Action and is nonetheless not diligently pursuing such Security Enforcement Action. 
 “Security
Interests” means the Liens created or purported to be created by or pursuant to the Security Documents. 
 “Security
Trustee” means the trustee named under the Common Security and Account Agreement as security trustee for the Secured Parties. 

“Senior Creditor” means a provider of Senior Debt that benefits from the Common Security and Account Agreement, including the
Facility Lenders, any Senior Noteholders and each Hedging Bank that is party to the Common Security and Account Agreement. 
 “Senior
Creditor Group” means, at any one time, the following, each of which will constitute a separate Senior Creditor Group: 
  

	 	(a)	the Term Lenders under the Term Loan Facility Agreement; 

 the Facility
Lenders (collectively) under any subsequent Facility Agreement; 
 the Senior Noteholders (collectively) under any
Indenture; 
 each Hedging Bank; and 

any Senior Creditor or group of Senior Creditors, as the case may be, that provides Additional Senior Debt pursuant to a
single Senior Debt Instrument entered into after the date of the Common Security and Account Agreement. 
 “Senior Creditor Group
Representative” means, with respect to any Senior Creditor Group, the representative of such Senior Creditor Group or the incumbent replacement thereof duly appointed as provided in Section 2.4 (Initial Senior Creditor Group
Representative; Replacement or Appointment of Senior Creditor Group Representative) of the Common Security and Account Agreement; provided that, in the case of Hedging Banks acting in the capacity as a Senior Creditor Group
Representative, such Hedging 

  
 A-68 

 
Bank shall only be entitled to act in such capacity in accordance with Section 7.3 (Hedging Banks) of the Common Security and Account Agreement. Each Facility Agent shall at all times
be the Senior Creditor Group Representative for the relevant Senior Creditor Group and each Indenture Trustee shall at all times be the Senior Creditor Group Representative for the relevant Senior Noteholders. 

“Senior Debt” means the Initial Senior Debt, the Working Capital Debt and Senior Notes under the applicable Senior Debt
Instrument existing on the Second Phase Closing Date, any other permitted Additional Senior Debt (including such as may be incurred under any Senior Notes, or any other Senior Debt Instrument) and debt incurred under the Permitted Senior Debt
Hedging Instruments, in each case benefiting from the Security Interests created under and pursuant to the Common Security and Account Agreement and incurred from time to time as permitted by the Finance Documents. 

“Senior Debt Commitments” means the aggregate principal amount any Senior Creditor is committed to disburse to the
Borrower under any Senior Debt Instrument. 
 “Senior Debt Hedging Termination Amount” means any Permitted Senior Debt
Hedging Liability falling due as a result of the termination of a Permitted Senior Debt Hedging Instrument or of any other transaction thereunder. 

“Senior Debt Instrument” means: 
  

	 	(a)	each Facility Agreement, including with respect to each Facility Agreement, the Common Terms Agreement; 

any Indenture and any Senior Notes issued pursuant to such Indenture; and 

any credit agreement, indenture, trust deed, note or other instrument pursuant to which the Borrower incurs permitted
Additional Senior Debt from time to time. 
 For the avoidance of doubt, the term “Senior Debt Instrument” shall not include
any Permitted Hedging Instrument (including, for the avoidance of doubt, any Permitted Senior Debt Hedging Instrument). 
 “Senior
Debt Obligations” means the obligations of the Borrower and the obligations of each Guarantor under its guarantee granted under and pursuant to the Common Security and Account Agreement in each case to pay: 

 

	 	(a)	all principal, interest and premiums on the disbursed Senior Debt; 

 all
commissions, fees, reimbursements, indemnities, prepayment premiums and other amounts payable to Senior Creditors under any Senior Debt Instrument; 

all Permitted Senior Debt Hedging Liabilities under Permitted Hedging Instruments that benefit from the Security Interests;
and 
 all Secured Party Fees; 

  
 A-69 

 in each case whether such obligations are present, future, actual or contingent and including the
payment of amounts that would become due under the Senior Debt Instruments but for the operation of the automatic stay under Section 362(a) of the Bankruptcy Code. 

“Senior Debt Service Reserve Account” is the account described in Section 4.3(a)(vii) (Accounts) of the
Common Security and Account Agreement. 
 “Senior Debt Reserve Shortfall” means, as of any date following the Project
Completion Date, the excess, if any, of the Reserve Amount over the balance in the Senior Debt Service Reserve Account (including Acceptable Debt Service Reserve LCs earmarked to such account), in each case as of such date. 

“Senior Debt/Equity Ratio” means, as of the date of measurement, the ratio of (a) the sum of principal amounts of Senior
Debt (excluding any Working Capital Debt and excluding Replacement Debt Incremental Amounts) incurred as of such date or Senior Debt or Senior Debt Commitments projected as of such date to be incurred under the Base Case Forecast, as applicable, to
(b) the aggregate amount of Equity Funding applied as of such date towards Project Costs (including any Cash Flow from operations prior to the Project Completion Date applied towards Project Costs) or Equity Funding commitments or Cash Flow
from operations projected as of such date to be applied towards Project Costs under the Base Case Forecast (including Equity Funding constituting Cash Flow that is reasonably expected to be received by the Loan Parties on or prior to the Project
Completion Date), as applicable. 
 “Senior Note Disbursement Accounts” has the meaning given in Section 4.3(a)(ii)
(Accounts) of the Common Security and Account Agreement. 
 “Senior Noteholder” means any holder of Senior Notes (or
lenders in the case of a “term loan B” financing that the Borrower has elected to be treated as an Indenture). 
 “Senior
Notes” means the notes to be issued (or facility agreement to be entered into in the case of a “term loan B” financing that the Borrower has elected to be treated as an Indenture) pursuant to any Indenture. 

“SG Agency Fee Letter” means the fee letter, dated on or about the date of the Common Security and Account Agreement, entered
into between the Company and Société Générale, in respect of the fees payable to Société Générale in its capacity as (i) the Security Trustee for the services rendered by the Security
Trustee under the Common Security and Account Agreement and the other Security Documents and the Direct Agreements, (ii) the Intercreditor Agent for the services rendered by the Intercreditor Agent under the Common Terms Agreement and the other
Finance Documents and (iii) the Term Loan Facility Agent in respect of its agency services to be performed under the Term Loan Facility Agreement and the other Security Documents. 

“Signing Date” means May 13, 2015. 

  
 A-70 

 “SIGTTO” has the meaning given in this Section 1.3 of Schedule A (Common
Definitions and Rules of Interpretation – Definitions) within the definition of International LNG Terminal Standards. 

“Site” means, collectively, each parcel or tract of land upon which any portion of the Project Facilities are or will be
located. 
 “Solvent” means, with respect to any Person as of the date of any determination, that on such date: 

 

	 	(a)	the fair valuation of the assets of such Person, on a consolidated basis, is greater than the liabilities of such Person on a consolidated basis, including, without limitation, contingent liabilities; 

the present fair saleable value of the assets of such Person, on a consolidated basis, is at least the amount that will be
required to pay the probable liability, on a consolidated basis, of such Person on its debts as they become absolute and matured; 

such Person is able to pay its debts and other liabilities, contingent obligations, and other commitments as they become
absolute and matured in the normal course of business; and 
 such Person is not engaged in business or a transaction, and
is not about to engage in business or a transaction, for which such Person’s assets would constitute unreasonably small capital after giving due consideration to current and anticipated future business conduct. 

In computing the amount of contingent liabilities at any time, such liabilities shall be computed at the amount which, in light of the facts
and circumstances existing at such time, represents the amount that can reasonably be expected to become an actual or matured liability. 

“Sponsor” means Cheniere Energy, Inc. a corporation organized under the laws of the State of Delaware. 

“State of New York,” “New York” or “NY” means the State of New York in the United States.

 “Subordinated Debt” means any debt or obligation that ranks subordinate in right of payment to the Senior Debt
Obligations, on the basis set forth in a subordination agreement in the form set forth in Schedule S – 1 (Form of General Subordination Agreement) or Schedule S – 2 (Form of Loan Party Subordination Agreement) to the
Common Terms Agreement, as the case may be. 
 “Subproject” has the meaning given in each Applicable EPC Contract. 

  
 A-71 

 “Subsequent Material Project Agreements” means any contract, agreement, letter
agreement or other instrument (other than a Real Property Document) to which a Loan Party becomes a party after the Second Phase Closing Date that: 
  

	 	(a)	replaces or substitutes for an existing Material Project Agreement; 

 with
respect to any Gas supply contract between any Loan Party and any Gas supplier or any Gas transportation contract between any Loan Party and any Qualified Transporter, (i) contains obligations and liabilities that are in excess of
$20 million per year and (ii) is for a term that is greater than seven years; 
 is a CCP Construction Contract;

 except as provided in clause (b) and (c) above, (i) contains obligations and liabilities that are in excess of
$50 million over its term (including after taking into account all amendments, amendments and restatements, supplements, or waivers to any such contract, agreement, letter agreement or other instrument) and (ii) is for a term that is
greater than seven years; provided that the following shall not constitute Subsequent Material Project Agreements: (A) any construction contracts entered into following the Second Phase Closing Date (excluding the CCP Construction
Contracts covered under clause (c) above), until such time as any Loan Party has entered into construction contracts following the Second Phase Closing Date that contain obligations and liabilities which in the aggregate are equal to at least
$100 million, (B) any LNG SPAs that are not Qualifying LNG SPAs and any guarantee thereof, (C) prior to the incurrence of any PDE Senior Debt, any contract, agreements, letter agreement or other instrument containing obligations or
liabilities of a Loan Party which is not effective by its terms unless and until PDE Senior Debt is incurred, and (D) prior to the incurrence of any Expansion Senior Debt following the Second Phase Closing Date, any contract, agreement, letter
agreement or other instrument containing obligations or liabilities which is not effective by its terms unless and until the Expansion Senior Debt is incurred; or 

is a guarantee provided in favor of any Loan Party by a guarantor or a counterparty under a Subsequent Material Project
Agreement. 
 For the purposes of this definition, any series of related transactions shall be considered as one transaction, and all
contracts, agreements, letter agreements or other instruments in respect of such transactions shall be considered as one contract, agreement, letter agreement or other instrument, as applicable. Subsequent Material Project Agreements that are
executed in a form previously attached to a Material Project Agreement (or Subsequent Material Project Agreement approved by the Intercreditor Agent (acting at the direction of the Requisite Intercreditor Parties)) will not be subject to the prior
Intercreditor Agent approval requirements set forth in Section 12.5 (Material Project Agreements) of the Common Terms Agreement; provided that, the notice requirements in Section 10.3(o) and 10.3(p) shall apply to such
Subsequent Material Project Agreements. 

  
 A-72 

 “Subsidiary” means, for any Person, any corporation, partnership, joint venture,
limited liability company or other entity of which at least a majority of the securities or other ownership interests having by their terms ordinary voting power to elect a majority of the board of directors or other Persons performing similar
functions of such corporation, partnership or other entity (irrespective of whether or not at the time securities or other ownership interests of any other class or classes of such corporation, partnership or other entity shall have or might have
voting power by reason of the happening of any contingency) is at the time directly or indirectly owned or Controlled by such Person or one or more Subsidiaries of such Person or by such Person and one or more Subsidiaries of such Person and
“Subsidiaries” shall have a corresponding meaning. 
 “Substantial Completion” has the meaning given in
each Applicable EPC Contract. 
 “Summary Milestone Schedule” means a summary of selected CPM Schedule milestones, extracted
from the Level III CPM Schedule (each as defined in each Applicable EPC Contract) substantially in the form acceptable to the Independent Engineer, listing for each contained milestone: early start date, early finish date, late start date, late
finish date, and days of float. 
 “Supplemental Quantity” means the portion of the Corpus Christi Terminal Facility’s
annual LNG production that is in excess of the volumes of LNG committed under the Initial LNG SPAs, the Second Phase LNG SPAs and any other Qualifying LNG SPA. 

“Supplies and Raw Materials” means all fuel, feedstock, materials, stores, spare parts and supplies and other personal
property which are consumable (otherwise than by ordinary wear and tear) in the operation and maintenance of the Project Facilities. 

“Supply Manager” means Cheniere Energy Shared Services, Inc. 

“Survey” means an American Land Title Association (“ALTA”) survey of the portion of the Site comprising the
Corpus Christi Terminal Facility showing a state of facts reasonably acceptable to the Security Trustee prepared by an independent surveyor licensed in the State of Texas in compliance with the 2011 ALTA/ACSM Minimum Standard Detail Requirements for
ALTA/ACSM Surveys and otherwise sufficient for the Title Company to eliminate the standard survey exception from the Title Policy. 

“Swap Obligation” means any obligation to pay or perform under any agreement, contract or transaction that constitutes a
“swap” within the meaning of Section 1a(47) of the Commodity Exchange Act or the regulations thereunder. 
 “Swing
Swap” means an contract which entitles the buyer of the contract to pay a fixed price for natural gas and the seller to pay the gas daily average at a defined location for a defined period of time. The Swing Swap is settled financially, via
exchange of cash payment each day as the gas daily average is settled, rather than physically. 
 “Targa Gas Supply
Agreement” means the agreement with Targa Gas Marketing LLC consisting of (a) the Base Contract for Sale and Purchase of Natural Gas, dated as of May 1, 2016, and (b) when executed and delivered, the related transaction
confirmation for a daily contract quantity of approximately 100,000 MMBtu. 

  
 A-73 

 “Tax Sharing Agreements” means the Tax Sharing Agreement, dated as of
May 13, 2015 between the Sponsor and CCP, and the Tax Sharing Agreement, dated as of May 13, 2015, between the Sponsor and CCL to allocate tax liabilities among the signing entities. 

“Taxes” means all present or future taxes, levies, imposts, duties, deductions, withholdings, assessments, fees or other
charges, including any interest, additions to tax or penalties applicable thereto, imposed by any Governmental Authority or the government of any foreign jurisdiction, or of any political subdivision thereof, including any and all agencies,
branches, departments and administrative and other subdivisions thereof, and any payments in lieu of the foregoing. 

“TBtu” means one trillion Btus. 

“Technical Services Agreement” means the technical services agreement, dated as of June 23, 2017, between Corpus Christi
Liquefaction Stage II, LLC and the EPC Contractor. 
 “Technology License Agreement (T1/T2)” means the license agreement
between ConocoPhillips and CCL relating to the Optimized Cascade Process for Subproject 1 and Subproject 2, as defined in the EPC Contract (T1/T2), to be used at the Corpus Christi Terminal Facility. 

“Technology License Agreement (T3)” means the license agreement between ConocoPhillips and CCL relating to the Optimized
Cascade Process for Subproject 3, as defined in the EPC Contract (T3), to be used at the Corpus Christi Terminal Facility. 

“Technology Licensor” means the provider of Technology License Agreement (T1/T2) and Technology License Agreement (T3). 

“Term Lenders” has the meaning given to it in the Term Loan Facility Agreement. 

“Term Loan Availability Period” has the meaning given to it in the Term Loan Facility Agreement. 

“Term Loan Facility Agent” means the facility agent under the Term Loan Facility Agreement. 

“Term Loan Facility Agreement” is the Amended and Restated Term Loan Facility Agreement, dated as of the Second Phase Closing
Date. 
 “Term Loan Facility Debt Commitment” has the meaning given in Exhibit A (Definitions) to the Term Loan
Facility Agreement. 
 “Term Loans” has the meaning given in the Term Loan Facility Agreement. 

“Texas Utilities Code” means Tex. Util. Code Ann. (Vernon 2015). 

  
 A-74 

 “TGP” means Tennessee Gas Pipeline Company, LLC, a limited liability company
organized under the laws of the State of Delaware. 
 “TGP Precedent Agreement” means the precedent agreement, dated as of
October 8, 2014, between CCL and TGP pursuant to which TGP will provide firm transportation services. 
 “Third Party Account
Bank” has the meaning given in Section 4.11(a) (Account with Third Party Account Bank) of the Common Security and Account Agreement. 

“Third Party Investment Account” has the meaning given in Section 4.11(a) (Account with Third Party Account Bank)
of the Common Security and Account Agreement. 
 “Title Company” means Fidelity National Title Insurance Company, First
American Title Insurance Company or Stewart Title Guaranty Company. 
 “Title Policy” means one or more fully paid Loan
Policies of Title Insurance (Form T-2) of title insurance as adopted for use in the State of Texas, or a pro forma policy prepared prior to payment for, issuance and delivery of the policy, with
completed Schedules A and B, showing the proposed insured, the amount of insurance, the exceptions that are proposed to be placed in the final policies to be issued, and the name of the title insurance company and title insurance agent, including
all amendments and endorsements thereto, issued by the Title Company in favor of the Security Trustee, with such coinsurers or reinsurers as may be reasonably required by the Security Trustee, with such policies: 

(a) in the case of the Title Policy delivered in connection with the Second Phase Closing Date, in an amount equal to the lesser of the
aggregate amount of the Loans and the maximum amount permitted to be insured under Section 2551.301 of the Texas Insurance Code as of the Second Phase Closing Date; 

(b) in the case of a Title Policy obtained in connection with an acquisition of Real Estate after the Second Phase Closing Date, to the extent
that the Loan Parties are required to obtain such policy in respect of such Real Estate acquisition pursuant to the Common Terms Agreement or Common Security Agreement, then: 

(x) in the case such acquisition of Real Estate is for purposes of an Expansion or Development Expenditure to be funded by Loans incurred by
the Loan Parties, the Loan Parties shall either amend the then-existing Title Policy, replace the then-existing Title Policy with a new Title Policy or, to the extent a tie-in endorsement to the then existing
Title Policy obtained in connection with incurrence of Loans is available and obtained, obtain a separate incremental Title Policy covering the acquired Real Estate, in each case, in an amount equal to the lesser of, when taken together with any
other then-existing Title Policy, (i) the aggregate amount of the outstanding principal of, and commitments in respect of, the Loans and (ii) the maximum amount permitted to be insured under Section 2551.301 of the Texas Insurance
Code at the time such policy is obtained; and 

  
 A-75 

 (y) in the case of an acquisition of any Real Estate by the Loan Parties other than in the
circumstances described in clause (x) above, the Loan Parties may (but shall not be required to) amend the then-existing Title Policy or replace the then-existing Title Policy with a new Title Policy in an amount consistent with the terms in
clause (x) above or shall obtain a Title Policy covering only such acquired Real Estate in an amount not less than the market value, as reasonably determined by the Borrower, of such acquired Real Estate; 

in each case with respect to such acquired Real Estate, and in form or forms satisfactory to the Security Trustee in all respects, with such
policies when taken together insuring as of the date of the recording of the applicable deed of trust required under Section 3.2(f) (Real Property) of the Common Security and Account Agreement creating a Lien on the estates and interests
in the Real Estate comprising the Corpus Christi Terminal Facility, that such deed of trust is a first and prior Lien on the estates and interests in the real property comprising the Corpus Christi Terminal Facility (to the extent the deed of trust
property consists of interests insurable under the terms of such form of title policy) free and clear of all Liens on and defects of title other than Permitted Liens, and containing or providing for, among other items: 

 

	 	(a)	no survey exceptions other than those approved by the Security Trustee; 

 the
lien exception and pending disbursements clause added to Schedule B as required by Procedural Rule P-8.b.1 of The Basic Manual of Rules, Rates and Forms for the Writing of Title Insurance in the State of
Texas; and 
 such endorsements and affirmative assurances as the Security Trustee shall reasonably require and which the
title insurers are permitted and willing to issue as provided in The Basic Manual of Rules, Rates and Forms for the Writing of Title Insurance in the State of Texas. 

“Trade Secret Licenses” means any and all agreements providing for the granting of any right in or to Trade Secrets (whether a
Loan Party is licensee or licensor thereunder) or otherwise providing for a covenant not to sue for misappropriation or other violation of a Trade Secret. 

“Trade Secrets” means all trade secrets and all other confidential or proprietary information and know-how, manufacturing and production processes and techniques, inventions, research and development information, technical data, financial, marketing and business data, pricing and cost information, business and
marketing plans, and customer and supplier lists and information whether or not the foregoing has been reduced to a writing or other tangible form, including all documents and things embodying, incorporating, or referring in any way to the
foregoing, and with respect to any and all of the foregoing: 
  

	 	(a)	all rights to sue or otherwise recover for any past, present and future misappropriation or other violation thereof; 

  
 A-76 

 all proceeds of the foregoing, including license fees, royalties, income,
payments, claims, damages, and proceeds of suit now or hereafter due and/or payable with respect thereto; and 
 all other
rights of any kind accruing thereunder or pertaining thereto throughout the world. 
 “Trademark Licenses” means any and all
agreements, licenses and covenants providing for the granting of any right in or to any Trademark or otherwise providing for a covenant not to sue for infringement, dilution or other violation of any Trademark or permitting co-existence with respect to a Trademark (whether a Loan Party is licensee or licensor thereunder). 

“Trademarks” means all United States, foreign and multinational trademarks, trade names, trade styles, trade dress, corporate
names, company names, business names, fictitious business names, Internet domain names, service marks, certification marks, collective marks, logos, other source or business identifiers, designs and general intangibles of a like nature, whether or
not registered, and with respect to any and all of the foregoing: 
  

	 	(a)	all registrations and applications therefor including the registrations and applications required to be listed in Schedule J (Intellectual Property) to the Common Security and Account Agreement under the heading
“Trademarks” (as such schedule may be amended from time to time); 

 all extensions and renewals of
any of the foregoing and amendments thereto; 
 all of the goodwill of the business connected with the use of and
symbolized by any of the foregoing; 
 all rights to sue or otherwise recover for any past, present and future
infringement, dilution or other violation of any of the foregoing or for any injury to the related goodwill; 
 all
proceeds of the foregoing, including license fees, royalties, income, payments, claims, damages, and proceeds of suit now or hereafter due and/or payable with respect thereto; and 

all other rights of any kind accruing thereunder or pertaining thereto throughout the world. 

“Trafigura” means Trafigura Pte Ltd, a Singaporean energy trading company that is an LNG Buyer. 

“Trafigura LNG SPA” means the LNG sale and purchase agreement, dated as of May 16, 2018, between CCL and Trafigura. 

“Train” means an LNG liquefaction train. 

  
 A-77 

 “Train One” means LNG Train 1 (as defined in the EPC Contract (T1/T2)). 

“Train Three” means LNG Train 3 (as defined in the EPC Contract (T3)). 

“Train Two” means LNG Train 2 (as defined in the EPC Contract (T1/T2)). 

“Tranche” has the meaning given in Exhibit A (Definitions) of the Term Loan Facility Agreement. 

“Transaction Documents” means, collectively, the Finance Documents and the Material Project Agreements. 

“Transfers” has the meaning given in the relevant Facility Agreement. 

“UCC” means the Uniform Commercial Code (or any similar or equivalent legislation) as in effect from time to time in any
applicable jurisdiction. 
 “United States” or “US” means the United States of America. 

“Unmatured Event of Default” means an Unmatured Loan Facility Event of Default, Unmatured Indenture Event of Default or a
comparable unmatured event of default under any other Senior Debt Instrument entered into after the date of the Common Security and Account Agreement. 

“Unmatured Indenture Event of Default” means an event that, with the giving of notice, lapse of time or making of a
determination, would constitute an Indenture Event of Default. 
 “Unmatured LNG SPA Prepayment Event” means an event that,
with the giving of notice or lapse of a cure period, would become an LNG SPA Prepayment Event. 
 “Unmatured Loan Facility Event of
Default” means a misrepresentation, breach of undertaking or other event or condition that has occurred and that, with the giving of notice or lapse of time or making of a determination, would constitute a Loan Facility Event of Default.

 “US Dollars” and “$” means the currency of the United States. 

“USPTO” means the United States Patent and Trademark Office. 

“US Tax Compliance Certificate” has the meaning given in Section 21.5(b)(ii)(D) (Status of Facility Lenders and
Facility Agents) of the Common Terms Agreement. 
 “USA Patriot Act” means the Uniting and Strengthening America by
Providing Appropriate Tools Required to Intercept and Obstruct Terrorism Act of 2001, as amended from time to time. 

  
 A-78 

 “Withdrawal and Transfer Certificate” means a certificate, in the form attached
as Schedule K (Form of Withdrawal and Transfer Certificate) to the Common Security and Account Agreement. 
 “Withdrawal
Liability” means any liability to a Multiemployer Plan as a result of a complete or partial withdrawal from such Multiemployer Plan, as such terms are defined in Sections 4203 and 4205 of ERISA. 

“Woodside” means Woodside Energy Trading Singapore Pte. Ltd., a Singaporean company that is an Initial LNG Buyer. 

“Work” has the meaning given in each Applicable EPC Contract. 

“Working Capital Debt” has the meaning given in Section 6.2 (Working Capital Debt) of the Common Terms Agreement.

 “Working Capital Facility Agent” has the meaning given in the preamble of the Common Terms Agreement. 

“Working Capital Facility Agreement” means the Working Capital Facility Agreement, dated as of December 14, 2016, among
the Borrower, the Guarantors, The Bank of Nova Scotia, as Working Capital Facility Agent, The Bank of Nova Scotia and Sumitomo Mitsui Banking Corporation, as Issuing Banks, Mizuho Bank, Ltd., as Swing Line Lender, and the lenders party thereto from
time to time. 
 “Working Capital Lenders” has the meaning given in the Working Capital Facility Agreement. 

  
 A-79EX-10.4

 Exhibit 10.4 

EXECUTION VERSION 
  

 
  

AMENDED AND RESTATED 

PLEDGE AGREEMENT 
 between

 CHENIERE CCH HOLDCO I, LLC, 

a Delaware limited liability company 

(Pledgor) 
 and 

SOCIÉTÉ GÉNÉRALE, 

(the Security Trustee) 
 Dated as
of May 22, 2018 
  
  

 

 TABLE OF CONTENTS 

 

							
	 	 	 	  	Page	 
	 ARTICLE I. DEFINITIONS
	  	 	2	 
			
	 1.1
	 	Defined Terms	  	 	2	 
	 1.2
	 	Common Security and Account Agreement and UCC Definitions	  	 	3	 
	 1.3
	 	Rules of Interpretation	  	 	3	 
		
	 ARTICLE II. PLEDGE AND GRANT OF SECURITY INTEREST
	  	 	3	 
			
	 2.1
	 	Granting Clause	  	 	3	 
	 2.2
	 	Perfection of Security Interest	  	 	5	 
		
	 ARTICLE III. OBLIGATIONS SECURED
	  	 	5	 
		
	 ARTICLE IV. REPRESENTATIONS AND WARRANTIES OF PLEDGOR
	  	 	5	 
			
	 4.1
	 	Organization	  	 	5	 
	 4.2
	 	Power and Authorization; Enforceable Obligations	  	 	5	 
	 4.3
	 	Valid Lien; Perfection	  	 	6	 
	 4.4
	 	No Legal Bar	  	 	6	 
	 4.5
	 	Beneficial Ownership; Pledged LLC Interests.	  	 	6	 
	 4.6
	 	No Prior Assignment	  	 	6	 
	 4.7
	 	No Other Financing Statements	  	 	6	 
	 4.8
	 	Name; Organizational Number	  	 	7	 
	 4.9
	 	Capital Adequacy; Etc.	  	 	7	 
	 4.10
	 	Changes in Circumstances	  	 	7	 
	 4.11
	 	Sole Purpose Nature; Business	  	 	7	 
	 4.12
	 	Indebtedness	  	 	7	 
	 4.13
	 	No Default Under Constitutional Documents	  	 	7	 
	 4.14
	 	No Litigation	  	 	7	 
	 4.15
	 	Taxes	  	 	7	 
	 4.16
	 	Investment Company Act	  	 	8	 
		
	 ARTICLE V. COVENANTS OF PLEDGOR
	  	 	8	 
			
	 5.1
	 	Defense of Collateral	  	 	8	 
	 5.2
	 	Continuation of Perfection; Preservation of Value	  	 	8	 
	 5.3
	 	Filing of Financing and Continuation Statements	  	 	9	 

  
 i 

							
	 5.4
	 	Limitation of Liens; No Sale	  	 	9	 
	 5.5
	 	No Other Filings	  	 	9	 
	 5.6
	 	Restrictions on Indebtedness	  	 	9	 
	 5.7
	 	Filing of Bankruptcy Proceedings	  	 	9	 
	 5.8
	 	Proceeds of Collateral	  	 	10	 
	 5.9
	 	Maintenance of Records	  	 	10	 
	 5.10
	 	Certificated Securities	  	 	10	 
	 5.11
	 	Pledged LLC Interests	  	 	10	 
	 5.12
	 	Change in Business	  	 	11	 
	 5.13
	 	Separateness	  	 	11	 
	 5.14
	 	Maintenance of Existence, Etc.	  	 	11	 
	 5.15
	 	Merger and Liquidation, Sale of All Assets	  	 	12	 
		
	 ARTICLE VI. REMEDIES UPON EVENT OF DEFAULT
	  	 	12	 
			
	 6.1
	 	Remedies Generally	  	 	12	 
	 6.2
	 	Remedies Upon an Event of Default	  	 	12	 
	 6.3
	 	Application of Proceeds	  	 	12	 
	 6.4
	 	Rights and Pledgor Obligations	  	 	12	 
	 6.5
	 	Delivery of Collateral; Proxy	  	 	13	 
		
	 ARTICLE VII. MISCELLANEOUS
	  	 	13	 
			
	 7.1
	 	Remedies Cumulative; Separate Actions	  	 	13	 
	 7.2
	 	Waiver of Rights of Subrogation	  	 	14	 
	 7.3
	 	Understanding With Respect to Remedies, Waivers and Consents	  	 	14	 
	 7.4
	 	Attorney-in-Fact	  	 	14	 
	 7.5
	 	Continuing Assignment and Security Interest, Transfer of Notes	  	 	15	 
	 7.6
	 	Security Interest Absolute	  	 	15	 
	 7.7
	 	Limitation on Duty of the Security Trustee with Respect to the Collateral	  	 	16	 
	 7.8
	 	Amendments; Waivers; Consents	  	 	17	 
	 7.9
	 	Termination	  	 	17	 
	 7.10
	 	Notices	  	 	17	 
	 7.11
	 	GOVERNING LAW	  	 	18	 
	 7.12
	 	Consent to Jurisdiction.	  	 	18	 
	 7.13
	 	WAIVER OF JURY TRIAL	  	 	19	 
	 7.14
	 	Reinstatement	  	 	20	 

  
 ii 

							
	 7.15
	 	Severability	  	 	20	 
	 7.16
	 	Survival of Provisions	  	 	20	 
	 7.17
	 	Successions or Assignments	  	 	20	 
	 7.18
	 	Headings Descriptive	  	 	20	 
	 7.19
	 	Entire Agreement	  	 	21	 
	 7.20
	 	Counterparts	  	 	21	 
	 7.21
	 	Limitation of Liability	  	 	21	 
	 7.22
	 	Third Party Beneficiaries	  	 	21	 
	 7.23
	 	Non Recourse	  	 	21	 
	 7.24
	 	Conflict	  	 	22	 
	 7.25
	 	Amendment and Restatement.	  	 	22	 

 EXHIBITS AND SCHEDULE 

Exhibit A – Form of LLC Interest Certificate 

Exhibit B – Limited Liability Company Interest Power 

Exhibit C – Irrevocable Proxy 
 Schedule I –
Description of Membership Interests 
 Schedule II – UCC Filing Jurisdiction 

Schedule III – Pledgor Information and Filing Details 

  
 iii 

 AMENDED AND RESTATED PLEDGE AGREEMENT 

This AMENDED AND RESTATED PLEDGE AGREEMENT, dated as of May 22, 2018 (as amended, amended and restated, supplemented or otherwise
modified from time to time, this “Agreement”), is entered into by and between CHENIERE CCH HOLDCO I, LLC, a limited liability company formed under the laws of the State of Delaware (“Pledgor”),
and SOCIÉTÉ GÉNÉRALE, in its capacity as Security Trustee for the Secured Parties (together with its successors and permitted assigns in such capacity, the “Security Trustee”). 

RECITALS 
 A. Cheniere
Corpus Christi Holdings, LLC, a limited liability company formed and existing under the laws of the State of Delaware and headquartered in Houston, Texas (the “Company”), intends to engage in the Development. 

B. The Company, the Guarantors, the Term Loan Facility Agent, each other Facility Agent party thereto, and the Intercreditor Agent have entered
into that certain Common Terms Agreement, dated as of May 13, 2015, as amended by the First Amendment to the Common Terms Agreement, dated as of September 25, 2015, and as amended and restated by that certain Amended and Restated Common
Terms Agreement, dated as of May 22, 2018 (as amended, amended and restated, supplemented or otherwise modified from time to time, the “Common Terms Agreement”), that sets out certain provisions regarding, among other
things, common representations and warranties of the Company and the Guarantors, common covenants of the Company and the Guarantors, and common Events of Default under the Loans. 

C. The Company, the Guarantors, the Senior Creditor Group Representatives party thereto, the Intercreditor Agent, the Security Trustee and the
Account Bank have entered into that certain Common Security and Account Agreement, dated as of May 13, 2015, as amended by that certain First Amendment to the Common Security and Account Agreement, dated as of September 7, 2017, and that
certain Second Amendment to the Common Security and Account Agreement, dated as of February 14, 2018, and as amended and restated by that certain Amended and Restated Common Security and Account Agreement, dated as of May 22, 2018 (as
amended, amended and restated, supplemented or otherwise modified from time to time, the “Common Security and Account Agreement”), that sets out certain provisions regarding the appointment and obligations of the Security
Trustee with respect to the Finance Documents. 
 D. The Pledgor and the Security Trustee have entered into that certain Pledge Agreement,
dated as of May 13, 2015 (the “Initial Pledge Agreement”), pursuant to which, among other things, the Pledgor granted the Security Trustee, for the benefit of the Secured Parties, a perfected first-priority interest in
the Collateral (as defined the Initial Pledge Agreement). 
 E. The Company, the Guarantors, the Term Lenders and the Term Loan Facility
Agent have entered into a Term Loan Facility Agreement dated as of May 13, 2015, as amended and restated by that certain Amended and Restated Term Loan Facility Agreement dated as of May 22, 2018 (as amended, amended and restated,
supplemented or otherwise modified from time to time), that sets out certain provisions regarding establishment by the Term Lenders of the credit facility to be used for the partial financing of the Development. 

 F. The Company, the Guarantors, the Working Capital Facility Agent, the Working Capital Lenders,
the Issuing Banks and the Swing Line Lender have entered into that certain Working Capital Facility Agreement, dated as of December 14, 2016, as amended by that certain First Amendment to the Working Capital Facility Agreement, dated as of
December 20, 2016 (as amended, amended and restated, supplemented or otherwise modified from time to time), that sets out certain provisions regarding establishment of the working capital facility to be used for the partial financing of the
Development. 
 G. The Company, the Guarantors and the Indenture Trustee have entered into an Indenture dated as of May 18, 2016, as
supplemented by the First Supplemental Indenture, dated as of December 9, 2016, and the Second Supplemental Indenture, dated as of May 19, 2017 (as amended, amended and restated, supplemented or otherwise modified from time to time),
pursuant to which the Company has issued, and may issue, several series of Senior Notes. 
 H. The Company, the applicable Secured Creditors
and the applicable Senior Creditor Group Representatives have entered, or may enter, into various Senior Debt Instruments under which the applicable Senior Creditors have agreed, or may agree, upon and subject to the terms of each such Senior Debt
Instrument, to provide Senior Debt to the Company. 
 I. The Company, the applicable Hedging Bank, Gas Hedge Provider or Power Hedge Provider
and the applicable Senior Creditor Group Representative have entered, or may enter, into various Permitted Hedging Instruments in order for the Company to hedge interest rate and other exposure under the Senior Debt Obligations. 

J. As of the date hereof, Pledgor is the only member of the Company and directly owns one hundred percent (100%) of the equity interests of the
Company, and will obtain benefits as a result of such loans and other financial accommodations to the Company under the Finance Documents. 

K. The Pledgor and the Security Trustee are entering into this Agreement in order to amend and restate the Initial Pledge Agreement and for the
Pledgor to grant the Security Trustee, for the benefit of the Secured Parties, a perfected first-priority interest (subject only to Permitted Equity Liens) in the Collateral (as defined herein). 

AGREEMENT 
 NOW,
THEREFORE, in consideration of the foregoing, and for other good and valuable consideration, the receipt and adequacy of which are hereby acknowledged, Pledgor hereby agrees with the Security Trustee, for the benefit of the Secured Parties, as
follows: 
 ARTICLE I. 

DEFINITIONS 
 1.1 Defined
Terms The following terms (whether or not underscored) when used in this Agreement, including its preamble and recitals, shall have the following meanings: 

  
 2 

 “Additional Pledge Agreement” means any Pledge Agreement between the
Security Trustee and any Additional Pledgor entered into pursuant to Section 5.11(a), which Pledge Agreement shall be substantially in the form of this Agreement. 

“Additional Pledgor” has the meaning given in Section 5.11(a)(i). 

“Collateral” has the meaning given in Section 2.1. 

“Company” has the meaning given in the recitals to this Agreement. 

“General Subordination Agreement” has the meaning given in Section 4.13. 

“Limited Liability Company Agreement” means the Amended and Restated Limited Liability Company Agreement of Cheniere
Corpus Christi Holdings, LLC dated as of March 30, 2015. 
 “Permitted Equity Liens” means (a) Liens for
Taxes not yet delinquent or which are being Contested, (b) Liens in favor, or for the benefit, of the Security Trustee and the other Secured Parties permitted pursuant to or required by this Agreement and the other Finance Documents, and
(c) restrictions on transfer under any Government Rules relating to securities. 
 “Pledged LLC Interests” has
the meaning given in Section 2.1(a). 
 “Pledgor” has the meaning given in the
preamble to this Agreement. 
 “Units” has the meaning given in the Limited Liability Company Agreement. 

1.2 Common Security and Account Agreement and UCC Definitions. Unless otherwise defined herein, all capitalized terms used in this
Agreement (and the preamble hereto) shall have the meanings provided in Schedule A (Common Definitions and Rules of Interpretation) of the Common Security and Account Agreement or, if not defined therein, the UCC. 

1.3 Rules of Interpretation. Unless otherwise provided herein, the rules of interpretation set forth in Section 1.2
(Interpretation) of Schedule A (Common Definitions and Rules of Interpretation) of the Common Security and Account Agreement shall apply to this Agreement, including its preamble and recitals, mutatis mutandis. 

ARTICLE II. 
 PLEDGE AND GRANT OF
SECURITY INTEREST 
 2.1 Granting Clause. To secure the timely payment in full in cash and performance of the Senior Debt
Obligations, Pledgor hereby assigns, grants, pledges, conveys and transfers to the Security Trustee, for the benefit of the Security Trustee and the other Secured Parties, a Lien on and continuing security interest in all the estate, right, title
and interest of Pledgor, whether now owned or hereafter existing or acquired by Pledgor, in, to and under any and all of the following (collectively, the “Collateral”): 

  
 3 

 (a) the limited liability company interests in the Company, including all of the Pledgor’s
capital or ownership interest (including capital accounts) (collectively, the “Pledged LLC Interest”), including the Units described on Schedule I hereto; 

(b) all of Pledgor’s rights to receive income, gain, profit, all shares, securities, membership or partnership interests, moneys or
property representing a dividend, and other distributions or return of capital allocated or distributed to Pledgor in respect of, or resulting from a split up, revision, reclassification or other like change of or otherwise in exchange for all or
any portion of the Pledged LLC Interests; 
 (c) all of Pledgor’s voting rights in or rights to control or direct the affairs of the
Company; 
 (d) all other rights, title and interest in or to the Company derived from the Pledged LLC Interests (including all rights of
Pledgor as a member of the Company under the Limited Liability Company Agreement); 
 (e) without affecting the obligations of the Company
or Pledgor under any provision prohibiting that action under any Finance Document, in the event of any consolidation or merger of the Company in which the Company is not the surviving entity, (i) all shares, securities, membership, partnership
or ownership interests, as applicable, of any successor entity formed by or resulting from that consolidation or merger including all rights, title, claims or interests associated therewith and (ii) all other consideration (including all
personal property, tangible or intangible) received by Pledgor for such items described in sub-clause (i); 

(f) all Subordinated Debt of the Company owed to Pledgor; 

(g) all claims of Pledgor for damages arising out of, or for any breach or default relating to, the Collateral, other than any claims against
the Security Trustee and the other Secured Parties; 
 (h) all rights of Pledgor to terminate, amend, supplement, modify, or cancel the
Constitutional Documents of the Company, to take all actions thereunder and to compel performance and otherwise exercise all remedies thereunder;  

(i) all notes, certificates and other instruments representing or evidencing any of the foregoing rights and interests or the ownership
thereof from time to time received, receivable or otherwise distributed in respect of or in exchange for any or all of such rights and interests; and 

(j) all proceeds, products and accessions (including “proceeds” as defined in
Section 9-102(a)(64) of the UCC) and all causes of action, claims and warranties now or hereafter held by Pledgor, in respect of any of the items listed above, of and to the foregoing Collateral, whether
cash or non-cash and, to the extent related to any property described in said clauses or such proceeds, all books, correspondence, credit files, records, invoices and other papers, including all tapes, cards,
computer runs, programs, printouts, databases and other computer materials, and documents in the possession or under the control of Pledgor; 

  
 4 

 provided, however, that “Collateral” shall not include any distributions by the Company
to Pledgor in accordance with the Limited Liability Company Agreement if such distributions are not prohibited by the terms of the Finance Documents. Notwithstanding anything herein to the contrary, this Agreement shall not grant a Lien on, or any
other right with respect to, any right, title or interest in any other property of the Pledgor (other than the Collateral). 
 2.2
Perfection of Security Interest. 
 Prior to or concurrently with the execution and delivery of this Agreement, Pledgor shall
(a) file such financing statements in such offices as is necessary (as identified on Schedule II attached hereto) or as the Security Trustee may request to perfect the security interests granted by Section 2.1
as a first-priority security interest (except with respect to Permitted Equity Liens) and (b) deliver to the Security Trustee certificates executed by the Company in the form of Exhibit A hereto, accompanied by limited liability company
interest powers executed by Pledgor in the form of Exhibit B hereto endorsed in blank and an irrevocable proxy, executed by Pledgor, in the form of Exhibit C hereto. 

ARTICLE III. 
 OBLIGATIONS SECURED

 Without limiting the generality of the foregoing, this Agreement and all of the Collateral secure the payment in full in cash when due of
all the Senior Debt Obligations. If, notwithstanding the representation and warranty set forth in Section 4.3 or anything to the contrary herein, enforcement of the liability of Pledgor under this Agreement for the full
amount of the Senior Debt Obligations would be an unlawful or voidable transfer under any applicable fraudulent conveyance or fraudulent transfer law or any comparable law, then the liability of Pledgor hereunder shall be reduced to the highest
amount for which such liability may then be enforced without giving rise to an unlawful or voidable transfer under any such law. 
 ARTICLE
IV. 
 REPRESENTATIONS AND WARRANTIES OF PLEDGOR 

Pledgor represents and warrants to and in favor of the Security Trustee and each other Secured Party, as of the date hereof, as follows: 

4.1 Organization. 

Pledgor is a Delaware limited liability company duly formed, validly existing and in good standing under the laws of the State of Delaware.

 4.2 Power and Authorization; Enforceable Obligations. 

4.2.1 Pledgor has the power and authority to: 

(a) execute, deliver, perform and incur obligations under this Agreement; and 

  
 5 

 (b) make the assignment and grant the Lien and Security Interest granted in the Collateral
pursuant to this Agreement. 
 4.2.2 The execution, delivery and performance of this Agreement has been duly authorized by the Pledgor, and
(assuming the due execution and delivery by the Security Trustee) is in full force and effect and constitutes a legal, valid and binding obligation of Pledgor, enforceable against it in accordance with its terms, except as limited by general
principles of equity and bankruptcy, insolvency and similar laws. 
 4.3 Valid Lien; Perfection. 

This Agreement is effective to create a legal, valid and enforceable Lien on, and security interest in, all of the Collateral, and the Secured
Parties have a first priority perfected security interest in the Collateral (subject to Permitted Equity Liens). 
 4.4 No Legal Bar.

 (a) The Pledgor’s Constitutional Documents do not conflict with or prevent execution or delivery or performance by it of the Finance
Documents to which it is a party; 
 (b) Neither (i) any material law applicable to Pledgor, or agreement to which it is a party, nor
(ii) any order, judgment or decree to which it or any of its assets are subject conflict in any material respect with, or prevent execution or delivery or performance by it of the Finance Documents to which it is a party or conflict in any
material respect with its Constitutional Documents; and 
 (c) The execution or delivery or performance by it of the Finance Documents to
which it is a party does not result in the creation or imposition of any Lien upon or with respect to any of its property or its assets now owned or hereafter acquired, other than Liens created under the Security Documents and other Permitted Equity
Liens. 
 4.5 Beneficial Ownership; Pledged LLC Interests. 

Pledgor owns good and valid title to all of its property and assets included in the Collateral, free and clear of all Liens other than
Permitted Equity Liens. 
 4.6 No Prior Assignment. 

No previous assignment of, or security interest in, Pledgor’s right, title and interest in any of the Collateral has been made or granted
by Pledgor. 
 4.7 No Other Financing Statements.  

Pledgor has not executed and is not aware of any effective financing statement, security agreement or other instrument similar in effect
covering all or any part of the Collateral on file in any recording office, except such as may have been filed pursuant to this Agreement and the other Finance Documents. 

  
 6 

 4.8 Name; Organizational Number. 

The full and correct legal name, type of organization, jurisdiction of organization, organizational ID number (if applicable) and mailing
address of Pledgor is correctly set forth in Schedule III hereto. 
 4.9 Capital Adequacy; Etc. 

Pledgor is not executing this Agreement with any intention to hinder, delay or defraud any present or future creditor or creditors of Pledgor.

 4.10 Changes in Circumstances. 

Pledgor has not (a) within the period of four months prior to the date hereof, changed its location (as defined in Section 9-307 of the UCC) or (b) heretofore become a “new debtor” (as defined in Section 9-102(a)(56) of the UCC) with respect to a currently
effective security agreement previously entered into by any other Person. 
 4.11 Sole Purpose Nature; Business. 

Pledgor has not conducted nor is conducting any business or activities other than activities related to owning the Collateral and other
business activities contemplated to be conducted by it in accordance with the Finance Documents. 
 4.12 Indebtedness. 

Pledgor has no Indebtedness other than Indebtedness created hereby, and Subordinated Debt as expressly permitted or contemplated by the General
Subordination Agreement, dated as of May 13, 2015, among the Pledgor, the Company, the Guarantors and the Security Trustee (the “General Subordination Agreement”). 

4.13 No Default Under Constitutional Documents. 

Pledgor is not in default of its obligations under any of its Constitutional Document. 

4.14 No Litigation. 

There is no action, suit or proceeding at law or in equity by or before any Governmental Authority or arbitral tribunal now pending, or to the
knowledge of Pledgor, threatened, against Pledgor or any of its property or the Collateral which could reasonably be expected to result in a Material Adverse Effect. 

4.15 Taxes. 
 Pledgor (or,
for the purposes of this Section 4.15, if it is a disregarded entity for US federal income tax purposes, its owner for US federal income tax purposes) has timely filed or caused to be filed all tax returns that are required to be

  
 7 

 
filed, and has paid (i) all Taxes shown to be due and payable on such returns or on any material assessments made against it or any of its property and (ii) all other material Taxes
imposed on it or its property by any Governmental Authority (other than Taxes the payment of which are not yet due, giving effect to any applicable extensions, or which are being contested in good faith), and no tax Liens (other than Permitted
Equity Liens) have been filed and no claims are being asserted with respect to any such Taxes (other than claims which are being contested in good faith). 

4.16 Investment Company Act. 

Pledgor is not, and after giving effect to the issuance of the Senior Debt and the application of proceeds of the Senior Debt in accordance
with the provisions of the Finance Documents shall not be, an “investment company” required to be registered under the Investment Company Act of 1940. 

ARTICLE V. 
 COVENANTS OF PLEDGOR

 Pledgor covenants to and in favor of the Security Trustee and the other Secured Parties, until the Discharge Date, as follows: 

5.1 Defense of Collateral. 

Pledgor shall defend its title to the Collateral and the first-priority perfected security interest (subject to Permitted Equity Liens) of the
Security Trustee (for the benefit the Secured Parties) in the Collateral against the claims and demands of all other Persons and shall contest in good faith to the extent permitted by applicable contractual obligations and Government Rules any
effort to exercise remedies with respect to Permitted Equity Liens. 
 5.2 Continuation of Perfection; Preservation of Value. 

(a) Pledgor agrees that from time to time, at its expense, it shall promptly execute and deliver all further instruments and documents, and
take all further action, that may be necessary or that the Security Trustee may reasonably request, in order to perfect, to ensure the continued perfection of, and to protect the assignment and security interest granted or intended to be granted
hereby or to enable the Security Trustee to exercise and enforce its rights and remedies hereunder with respect to any Collateral. Without limiting the generality of the foregoing, Pledgor shall (i) deliver all certificates evidencing the
Collateral or any part thereof to the Security Trustee, as the Security Trustee may reasonably request, accompanied by such duly executed instruments of transfer or assignment in form and substance reasonably acceptable to the Security Trustee, and
(ii) authorize, execute and file such other instruments, endorsements or notices, as may be necessary or as the Security Trustee may reasonably request, in order to perfect and preserve the assignments and first-priority security interests
granted or purported to be granted hereby (subject to Permitted Equity Liens). 
 (b) Pledgor shall, promptly upon request, provide to the
Security Trustee all information and evidence it may reasonably request concerning the Collateral to enable the Security Trustee to enforce the provisions of this Agreement. 

  
 8 

 5.3 Filing of Financing and Continuation Statements. 

Pledgor hereby authorizes the filing of any financing statements or continuation statements, and amendments to financing statements, or any
similar document in any jurisdictions and with any filing offices as the Security Trustee may determine in its sole discretion are necessary (or in its reasonable discretion are advisable) to perfect the security interest granted to the Security
Trustee herein, for the benefit of the Secured Parties. Such financing statements may describe the Collateral in the same manner as described herein or may contain an indication or description of the Collateral that describes such property in any
similar manner as the Security Trustee may determine, in its sole discretion, is necessary, advisable or prudent to ensure the perfection of the security interest in the Collateral granted to the Security Trustee herein. The Security Trustee shall
promptly deliver to Pledgor copies of any such statement, document or amendment. 
 5.4 Limitation of Liens; No Sale. 

(a) Pledgor shall not directly or indirectly create, incur, assume or suffer to exist any Liens (except Permitted Equity Liens) on or with
respect to all or any part of the Collateral. Pledgor shall at its own cost and expense promptly take such action as may be necessary to discharge any such Liens. Pledgor shall not take or permit to be taken any action in connection with the
Collateral which would impair the interests or rights of Pledgor therein or which would impair the interests or rights of the Security Trustee therein or with respect thereto, except as expressly permitted by the Finance Documents; and 

(b) Except as permitted by this Agreement and the other Finance Documents, Pledgor shall not cause, suffer or permit the sale, assignment,
conveyance, pledge or other transfer (by operation of law or otherwise) of all or any portion of Pledgor’s ownership or interest in the Company or any other portion of the Collateral. 

5.5 No Other Filings. 

Pledgor shall not file or suffer to be on file, or authorize or permit to be filed or to be on file, in any jurisdiction, any financing
statement or like instrument with respect to any of the Collateral in which the Security Trustee is not named as the sole secured party for the benefit of the Secured Parties, other than with respect to Permitted Equity Liens. 

5.6 Restrictions on Indebtedness. 

Pledgor shall not permit, create, incur, assume or suffer to exist any Indebtedness other than (a) Indebtedness created hereby and
(b) Subordinated Debt that is expressly subject to the General Subordination Agreement. 
 5.7 Filing of Bankruptcy Proceedings.

 To the extent permitted under applicable Government Rule, Pledgor, for itself, its successors and assigns, shall not cast any vote as
owner of the Pledged LLC Interests or otherwise in favor of any action that would result in a violation by the Company of any of its Constitutional Documents. 

  
 9 

 5.8 Proceeds of Collateral. 

Pledgor shall be permitted to receive and retain any distribution on any Collateral in accordance with the Limited Liability Company Agreement
if such distribution is not prohibited by the terms of the Finance Documents. If Pledgor (a) in its capacity as owner of the Pledged LLC Interests or otherwise receives any income, dividend or other distribution of money or property of any kind
from the Company (other than as permitted by the Finance Documents) or (b) receives any other dividend, distribution, interest, principal or other proceeds, securities or rights in relation to the Collateral (other than as permitted by the
Finance Documents), then Pledgor shall hold such distribution or other payment as trustee for and shall promptly deliver the same to the Security Trustee to be applied as required under the Finance Documents. 

5.9 Maintenance of Records. 

Pledgor shall: 
 (a) keep full
and accurate books and records relating to the Collateral in accordance with prudent business practice and, if reasonably requested by the Security Trustee, stamp or otherwise mark its books and records in such manner as the Security Trustee may
reasonably require in order to reflect the Liens granted by this Agreement; and 
 (b) subject to Section 12.6 of the Common Security
and Account Agreement, the provisions of Section 12.4(a) (Books and Records; Inspection Rights) of the Common Terms Agreement apply to this Agreement, mutatis mutandis, with the same effect as if any references in such
section to the “Loan Parties” were references to the “Pledgor” for the purposes of this Section 5.9. 
 5.10
Certificated Securities. 
 Pledgor shall cause its equity interests in the Company to be evidenced by and remain “certificated
securities” as defined in Article 8 of the UCC. 
 5.11 Pledged LLC Interests. 

(a) Pledgor may cause the Company to issue any additional limited liability company interests in the Company at any time (whether or not
certificated) unless such issuance is not permitted under the Common Terms Agreement and the other Finance Documents; provided, however, that such issuance shall only be permitted if the following occur: (i) provision is made for
the inclusion of such interest in the Collateral (as defined hereunder or in any Additional Pledge Agreement (which Additional Pledge Agreement shall be executed and delivered to the Security Trustee by the owner (any such owner, an
“Additional Pledgor”) of such additional limited liability company interests prior to the issuance thereof)), (ii) such interests are issued to Pledgor or any Additional Pledgor (or any of their respective successors and
permitted assigns), (iii) all action has been taken necessary to create, in favor of the Security Trustee for the benefit of the Secured Parties, a legal, valid and enforceable Lien on and first-priority security interest (subject to Permitted
Equity Liens) in such interests, and all necessary filings have been made in all necessary public offices, and all other necessary and appropriate action has been taken, so that this Agreement or the Additional Pledge Agreement, as applicable,

  
 10 

 
creates a first-priority perfected Lien (except with respect to Permitted Equity Liens) on and security interest in all right, title and interest in such interests, prior and superior to all
other Liens (subject to Permitted Equity Liens) and all necessary and appropriate consents to the creation, perfection and enforcement of such Liens have been obtained and (iv) the Security Trustee shall have received an opinion of counsel with
respect to such interests that is substantially similar to the opinions delivered on or before the Closing Date covering the matters described in clause (iii) above. Pledgor shall not permit (i) the Company to have outstanding any
subscription agreements, warrants, or options to acquire any limited liability company interests of whatever type; (ii) any limited liability company interest of the Company to be dealt in or traded on any securities exchange or in any
securities market; or (iii) any limited liability company interest of the Company to be deemed an investment company security (as defined in Section 8-103(b) of the UCC). 

(b) Unless the Security Trustee has, pursuant to and in accordance with ARTICLE VI below, delivered to Pledgor a notice directing Pledgor to
cease exercising its voting rights, Pledgor may exercise, as it deems fit, but in a manner that would not impair the Liens granted hereunder or be inconsistent with the terms of the Finance Documents, all voting, consensual and other powers and
rights (to the extent applicable) with respect to the Collateral. 
 5.12 Change in Business. 

Pledgor shall not enter into or engage in any business other than owning the Collateral and other business activities contemplated by and
otherwise in accordance with the Finance Documents. 
 5.13 Separateness. 

Pledgor shall take no action which would cause the Company to fail to comply at all times with the applicable separateness provisions set forth
in Section 12.24 to the Common Terms Agreement. 
 5.14 Maintenance of Existence, Etc. 

 

	 	(a)	Pledgor shall maintain its corporate existence; 

  

	 	(b)	Pledgor shall not take any action to amend or modify its Constitutional Documents in a manner that is in any material respect adverse to the interests of the Secured Parties or Pledgor’s ability to comply with the
Finance Documents; and 

  

	 	(c)	

  

	 	(i)	Pledgor shall promptly provide copies of any amendments to its Constitutional Documents to the Security Trustee; 

  

	 	(ii)	Pledgor shall not change, alter or modify its legal or business name from the name shown in Schedule III hereto., jurisdiction of organization or type of organization, in each case without providing the Security
Trustee with at least 30 days’ prior notice; and 

  
 11 

	 	(iii)	Pledgor shall not cease to be a partnership or an entity disregarded for US federal, state and local income tax purposes. 

5.15 Merger and Liquidation, Sale of All Assets. 

Pledgor shall take no action to liquidate itself, enter into any merger or sell or otherwise transfer all or substantially all its assets. 

ARTICLE VI. 
 REMEDIES UPON EVENT
OF DEFAULT 
 6.1 Remedies Generally. 

Following a Declared Event of Default, any and all remedies under this Agreement may be exercised from time to time subject to and in
accordance with the terms of the Intercreditor Agreement and Common Security and Account Agreement (including, for the avoidance of doubt, the receipt by the Security Trustee of a Security Enforcement Action Initiation Request or other instruction
in accordance with the Common Security and Account Agreement). 
 6.2 Remedies Upon an Event of Default. 

Subject in each case to Section 6.1 above, the Security Trustee shall have the right, at its election, but not the obligation, to exercise
all rights and remedies with respect to the Collateral of a secured party under the UCC (whether or not the UCC is in effect in the jurisdiction where the rights and remedies are asserted and otherwise exercise all rights and remedies with respect
to the Collateral provided under the Common Security and Account Agreement). Such rights and remedies shall be consistent and exercised in accordance with the applicable provisions of Article 6 (Security Trustee Action), Article 8 (The
Security Trustee) and Article 10 (Obligations Under Security Documents) of the Common Security and Account Agreement; provided, however, that any references to the “Company”, a “Securing Party” or a
“Collateral Party” in the Common Security and Account Agreement shall be interpreted as references to the “Pledgor” for the purposes of this Section 6.2. 

6.3 Application of Proceeds. 

The proceeds of any sale of, or other realization upon, all or any part of the Collateral shall be applied in accordance with the Common
Security and Account Agreement. 
 6.4 Rights and Pledgor Obligations. 

No reference in this Agreement to proceeds or to the sale or other disposition of Collateral shall authorize Pledgor to sell or otherwise
dispose of any part of the Collateral except as expressly permitted by this Agreement or the other Finance Documents. Neither the Security Trustee nor any other Secured Party shall be required to take steps necessary to preserve any rights against
prior parties to any part of the Collateral. 

  
 12 

 6.5 Delivery of Collateral; Proxy. 

The Security Trustee shall have the right, at any time in its discretion and without prior notice to Pledgor, following the occurrence and
during the Continuation of a Declared Event of Default and pursuant to a Security Enforcement Action Initiation Request in accordance with the Common Security and Account Agreement, to transfer to or to register in the name of the Security Trustee
or any of its nominees any or all of the Collateral and to exchange certificates or instruments representing or evidencing Collateral for certificates or instruments of smaller or larger denominations; provided, however, that once such
Event of Default has been cured or waived in accordance with the Finance Documents and the Security Trustee has received a Cessation Notice, the Security Trustee will promptly transfer to or register in the name or cause its nominees to transfer to
or register in the name of Pledgor all such Collateral. 
 Pledgor agrees when delivering any notices, documentation, instruments or
Collateral to the Security Trustee that Pledgor shall clearly identify to the Security Trustee the name of the Pledged LLC Interests and other Secured Parties associated therewith. 

ARTICLE VII. 
 MISCELLANEOUS 

7.1 Remedies Cumulative; Separate Actions. 

(a) No right, power or remedy herein conferred upon or reserved to the Security Trustee hereunder is intended to be exclusive of any other
right, power or remedy, and every such right, power and remedy shall, to the extent permitted by applicable Government Rules, be cumulative and in addition to every other right, power and remedy given hereunder or under any other Finance Document
now or hereafter existing at law or in equity or otherwise. The assertion or employment of any right or remedy hereunder, or otherwise, shall not prevent the concurrent assertion or employment of any other appropriate right or remedy. Resort to any
or all security now or hereafter held by the Security Trustee or any other Secured Party may be taken concurrently or successively and in one or several consolidated or independent judicial actions or lawfully taken nonjudicial proceedings, or both.
If the Security Trustee may, under applicable Government Rules, proceed to exercise its rights and remedies under this Agreement or any other Finance Document giving the Security Trustee a Lien upon any property securing the Senior Debt Obligations,
whether owned by Pledgor, the Company or by any other Person, either by judicial foreclosure or by nonjudicial sale or enforcement, the Security Trustee may, at its sole option, determine which of its remedies or rights it may pursue without
affecting any of the rights and remedies of the Security Trustee under this Agreement. 
 (b) Delay Not Waiver; Separate Causes of
Action. No failure on the part of the Security Trustee or any other Secured Party to exercise, and no course of dealing with respect to, and no delay or omission in exercising, any right, power or remedy hereunder shall operate as a waiver
thereof; nor shall any single or partial exercise by the Security Trustee or any other Secured Party of any right, power or remedy hereunder preclude any other or further 

  
 13 

 
exercise thereof or the exercise of any other right, power or remedy. No notice to or demand on Pledgor by the Security Trustee or any other Secured Party shall, in any case, entitle Pledgor to
any other or further notice or demand in similar or other circumstances or constitute a waiver of the rights of the Security Trustee or any other Secured Party to any other or further action in any circumstances without notice or demand. Any waiver,
permit, consent or approval of any kind or character on the part of the Security Trustee or any other Secured Party of any breach or default under this Agreement, or any waiver on the part of the Security Trustee or any other Secured Party of any
provision or condition of this Agreement, must be in writing and shall be effective only to the extent specifically set forth in such writing. Each and every default by Pledgor in payment hereunder shall give rise to a separate cause of action
hereunder, and separate suits may be brought hereunder as each cause of action arises and every power and remedy given by this Agreement may be exercised from time to time, and as often as shall be deemed expedient, by the Security Trustee. The
Security Trustee may bring and prosecute such separate action or actions against Pledgor, whether or not the Company or any other Person is joined in any such action (or a separate action or actions are brought against Pledgor, the Company, any
other Person or any Collateral) for all or any part of the Senior Debt Obligations. 
 7.2 Waiver of Rights of Subrogation. 

The waiver of subrogation set forth in Section 11.4 (No Subrogation) of the Common Security and Account Agreement shall apply to
this Agreement mutatis mutandis, with the same effect as if any references in such section to the “Guarantors” were references to the “Pledgor” for the purposes of this Section 7.2. 

7.3 Understanding With Respect to Remedies, Waivers and Consents. 

Pledgor represents, warrants and agrees that (a) it has received a conformed copy of the Common Security and Account Agreement and,
notwithstanding that it is not a party thereto, the Pledgor accepts and agrees to be bound by the terms and conditions thereof that are made applicable to this Agreement, and (b) the provision of clause (a) and each of the waivers and
consents set forth in this Agreement and the Common Security and Account Agreement with respect to it is made voluntarily, irrevocably and unconditionally after consultation with outside legal counsel and with full knowledge of its significance and
consequences, with the understanding that events giving rise to any defense or right waived may diminish, destroy or otherwise adversely affect rights which Pledgor otherwise may have against the Loan Parties, the Security Trustee, any other Secured
Party or any other Person or against any Collateral. If, notwithstanding the intent of the parties that the terms of this Agreement shall control in any and all circumstances, any such waivers or consents are determined to be unenforceable under
applicable Government Rules, such waivers and consents shall be effective to the maximum extent permitted by law. 
 7.4 Attorney-in-Fact. 
 Pledgor hereby constitutes and appoints
the Security Trustee, acting for and on behalf of itself and the other Secured Parties and on behalf of each successor or assign of the Security Trustee and the other Secured Parties, the true and lawful attorney-in-fact of Pledgor, with full power and authority in the place and stead of Pledgor and in the name of Pledgor, the 

  
 14 

 
Security Trustee or otherwise, as the Security Trustee may deem necessary, subject to the terms of the Common Terms Agreement and the other Finance Documents, to do anything permitted under
Section 8.3 (Attorney-in-Fact) of the Common Security and Account Agreement; provided, however, that the Security Trustee shall not exercise any such
rights unless a Declared Event of Default has occurred and is Continuing and only in accordance with the Intercreditor Agreement and Common Security and Account Agreement. This power of attorney is a power coupled with an interest and shall be
irrevocable prior to the Discharge Date; provided, however, that nothing in this Agreement shall prevent Pledgor from, prior to the exercise by the Security Trustee of any of the aforementioned rights, undertaking Pledgor’s
operations in the ordinary course of business in accordance with the Finance Documents to which the Pledgor is a party. 
 7.5 Continuing
Assignment and Security Interest, Transfer of Notes. 
 This Agreement shall create a continuing pledge and assignment of and
first-priority security interest in the Collateral (except with respect to Permitted Equity Liens) and shall (a) remain in full force and effect until the Discharge Date, (b) be binding upon Pledgor and its successors and assigns and
(c) inure, together with the rights and remedies of the Security Trustee, to the benefit of the Security Trustee, the other Secured Parties and their respective successors and permitted assigns. Without limiting the generality of the foregoing
clause (c), any of the Senior Creditors may assign or otherwise transfer the notes or other evidence of indebtedness held by them to any other Person to the extent permitted by and in accordance with the terms of the Senior Debt Instrument governing
the relevant Senior Debt and the other Finance Documents, and such other Person shall thereupon become vested with all or an appropriate part of the benefits in respect thereof granted to the Secured Parties herein or otherwise. The release of the
security interest in any or all of the Collateral, the taking or acceptance of additional security, or the resort by the Security Trustee to any security it may have in any order it may deem appropriate, shall not affect the liability of any Person
on the indebtedness secured hereby. 
 7.6 Security Interest Absolute. 

Until the Discharge Date, all rights of the Security Trustee and the other Secured Parties and the security interest hereunder, and all
obligations of Pledgor hereunder, shall be absolute and unconditional irrespective of: 
 (a) any lack of validity or enforceability of any
of the Finance Documents, any other Transaction Document or any other agreement or instrument relating thereto; 
 (b) the exercise by any
Secured Party of any remedy, power or privilege contained in any Finance Document or available at law, equity or otherwise; 
 (c) the
failure of any Secured Party or any holder of any note (i) to assert any claim or demand or to enforce any right or remedy against the Company, any Affiliate of the Company or any other Person under the provisions of any of the Finance
Documents, any other Transaction Document or otherwise or (ii) to exercise any right or remedy against any other guarantor of, or collateral securing, any of the Senior Debt Obligations; 

  
 15 

 (d) any change in the time, manner or place of payment of, or in any other term of the Senior
Debt Obligations (including any increase in the amount thereof), or any other amendment or waiver of or any consent to any departure from any of the Finance Documents or any other Transaction Document, except for any amendment, waiver, consent to
departure effected in accordance with the applicable Finance Documents and other Transaction Documents; 
 (e) any action by the Security
Trustee to take and hold security or Collateral for the payment of the Senior Debt Obligations, or to sell, exchange, release, dispose of, or otherwise deal with, any property pledged, mortgaged or conveyed, or in which the Security Trustee has been
granted a Lien, to secure any indebtedness to the Security Trustee of Pledgor, the Company, any of its Affiliates or any other Person party to a Transaction Document; 

(f) any reduction, limitation, impairment or termination of any of the Senior Debt Obligations for any reason other than the written agreement
of the Secured Parties to reduce, limit or terminate such Senior Debt Obligations and Pledgor hereby waives any right to or claim of, any defense or setoff, counterclaim, recoupment, or termination whatsoever by reason of the invalidity, illegality,
nongenuineness, irregularity, compromise, unenforceability of, or any other event or occurrence (other than the occurrence of the Discharge Date) affecting, any Obligation of the Company, any Affiliate of the Company or otherwise; 

(g) any amendment to, rescission, waiver, or other modification of, or any consent to departure from, any of the terms of any Finance Document
or any other Transaction Document except in accordance with the terms thereof; 
 (h) any exchange, surrender, release or non-perfection of any Collateral, or any release, amendment or waiver or addition of or consent to departure from any other security interest held by any Secured Party or any holder of any Note securing any of the
Senior Debt Obligations; 
 (i) the application by the Security Trustee of any sums by whomever paid or however realized to any amounts
owing by Pledgor, the Company or any other Person party to the Transaction Documents to the Security Trustee in accordance with the terms of the Finance Documents; 

(j) any bankruptcy or insolvency of the Company, Pledgor or any other Person; or 

(k) any other circumstance which might otherwise constitute a defense available to, or a discharge of, Pledgor or any third party pledgor
(other than the defense of payment). 
 7.7 Limitation on Duty of the Security Trustee with Respect to the Collateral. 

(a) The Pledgor acknowledges that the Security Trustee is acting on behalf of the Secured Parties and is entitled to the exculpation
provisions, indemnities and limitations of liability set out in the Common Security and Account Agreement, including without limitation Sections 8.1 (Appointment and Duties), 8.4 (Reliance), 8.5 (Liability), 8.6 (Consultation
with  

  
 16 

 
Counsel, Etc.), 8.8 (Indemnity), 8.10 (Certificates), 8.14 (Limitation on Security Trustee’s Duties in Respect of Collateral), 8.15 (Security Documents),
8.16 (Exculpatory Provisions), 8.19 (Treatment of Senior Creditors by the Security Trustee) and 8.20 (Compliance) of the Common Security and Account Agreement. 

(b) The Security Trustee’s obligations are limited to those expressly set out in the Common Security and Account Agreement and this
Agreement and the Security Trustee shall have all the benefits granted to it under the Common Security and Account Agreement (including the right to assign its rights and obligations under this Agreement in accordance with the Common Security and
Account Agreement if it ceases to be the Security Trustee thereunder). 
 7.8 Amendments; Waivers; Consents. 

None of the terms or provisions of this Agreement may be waived, amended, supplemented or otherwise modified except by agreement by the parties
hereto with the Security Trustee acting in the same manner and based on the same instructions set forth in Section 7.2(a) and (b) (Modifications to Other Finance Documents) of the Common Security and Account Agreement. 

7.9 Termination. 
 On the
Discharge Date, this Agreement and the Liens, security interests and all other rights granted to the Security Trustee and the other Secured Parties hereby shall terminate and all rights to the Collateral shall automatically revert to Pledgor. Upon
any such termination, the Security Trustee will return all certificates previously delivered to the Security Trustee representing the Pledged LLC Interests to Pledgor. The Security Trustee shall, at the expense of and upon written direction from
Pledgor, execute and deliver to Pledgor such documents (including UCC-3 termination statements) as Pledgor shall reasonably request to evidence such termination, to release all security interests on the
Collateral and to return such Collateral to Pledgor. 
 7.10 Notices. 

All notices required or permitted under the terms and provisions hereof shall be in writing, and any such notice shall be effective if given in
accordance with the provisions of Section 12.7 (Notices) of the Common Security and Account Agreement, mutatis mutandis. Notices to Pledgor or the Security Trustee may be given at the party’s respective address as set below: 

Pledgor: 
 CHENIERE CCH HOLDCO I,
LLC 
 700 Milam, Suite 1900 

Houston, Texas 77002 
 Attention:
Treasurer 
 Telephone: 713-375-5637 

Fax: 713-375-6000 

  
 17 

 Email: lisa.cohen@cheniere.com 

Security Trustee: 

Société Générale 

245 Park Avenue 
 New York, NY
10167 
 Attention: Ed Grimm 

Telephone: (212) 278-6450 

Fax: (212) 278-6136 

Email: edward.grimm@sgcib.com 

with a copy to: 

Société Générale 

245 Park Avenue 
 New York, NY
10167 
 Attention: Ellen Turkel 

Telephone: (212) 278-6437 

Fax: (212) 278-6136 

Email: ellen.turkel@sgcib.com 

7.11 GOVERNING LAW. 
 THIS
AGREEMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF NEW YORK, UNITED STATES WITHOUT REGARD TO CONFLICTS OF LAWS PRINCIPLES THEREOF THAT WOULD RESULT IN THE APPLICATION OF THE LAW OF ANY OTHER JURISDICTION. 

7.12 Consent to Jurisdiction.  
  

	 	(a)	All Parties to this Agreement hereby consent to the non-exclusive jurisdiction of the courts of the State of New York. 

 

	 	(b)	Each Party hereto: 

  

	 	(i)	hereby irrevocably consents and agrees for the benefit of the Secured Parties that the federal or state courts in the Borough of Manhattan, the City of New York shall have jurisdiction over any legal action, suit or
proceeding against it with respect to its obligations, liabilities or any other matter under or arising out of, or in connection with, this Agreement; 

  

	 	(ii)	irrevocably waives any objection it may now or hereafter have to the laying of venue of any action or proceeding in any such court and any claim it may now or hereafter have that any action or proceeding has been
brought in an inconvenient forum; and 

  
 18 

	 	(iii)	irrevocably consents and agrees that the submission to the jurisdiction of the federal or state courts in the Borough of Manhattan, the City of New York shall not limit the rights of the Security Trustee to bring any
action or proceeding in any other court of competent jurisdiction nor shall the bringing of any action or the taking of any proceedings in any other jurisdiction (whether concurrently or not) limit such rights, in each case, to the extent permitted
by applicable law. 

  

	 	(c)	Without prejudice to any other mode of service allowed under any relevant law, Pledgor: 

  

	 	(i)	agrees that failure by a process agent to notify it of the process will not invalidate the proceedings concerned; 

  

	 	(ii)	shall maintain a duly appointed and authorized agent for service of process in relation to any proceedings before the federal or state courts of the Borough of Manhattan, the City of New York in connection with this
Agreement and shall keep the Security Trustee advised of the identity and location of such agent and acknowledges that it shall appoint Corporation Service Company as its agent for service of process at its registered office (being, on the Signing
Date, at 1180 Avenue of the Americas, Suite 210, New York, NY 10036); and 

  

	 	(iii)	hereby irrevocably authorizes the Security Agent to appoint an agent for service of process on its behalf should it at any time fail to maintain in full force and effect a process agent in accordance with this
Section 7.12 (Consent to Jurisdiction.), and the Security Trustee shall promptly notify it of any such appointment. 

  

	 	(d)	Each of the Parties hereto agree that upon service of process to the Pledgor’s agent for service of process appointed for such purpose under clause (c) above, a copy of such process shall be delivered to
Pledgor, in accordance with the procedure for notices set forth in Section 12.7 (Notices) of the Common Security and Account Agreement, provided that the non-delivery of such copy shall not
affect the enforceability of such process validly served upon such agent. 

 7.13 WAIVER OF JURY TRIAL. 

EACH PARTY HERETO HEREBY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY AND ALL RIGHT TO TRIAL BY JURY IN ANY LEGAL PROCEEDING
ARISING OUT OF OR RELATING TO THIS AGREEMENT OR THE TRANSACTIONS CONTEMPLATED THEREBY. 

  
 19 

 7.14 Reinstatement. 

This Agreement and the Senior Debt Obligations shall continue to be effective or be automatically reinstated in the circumstances described in
Section 10.1(a) (Nature of Obligations) of the Common Security and Account Agreement, with the same effect as if any references in such section to the “Company” were references to the “Pledgor” for the purposes of
this Section 7.14. 
 7.15 Severability. 

If any provision of this Agreement is held to be illegal, invalid or unenforceable, (a) the legality, validity and enforceability of the
remaining provisions of this Agreement shall not be affected or impaired thereby and (b) the parties shall endeavor in good faith negotiations to replace the illegal, invalid or unenforceable provisions with valid provisions the commercial
effect of which comes as close as possible to that of the illegal, invalid or unenforceable provisions. The invalidity of a provision in a particular jurisdiction shall not invalidate or render unenforceable such provision in any other jurisdiction.

 7.16 Survival of Provisions. 

All agreements, representations and warranties made herein shall survive the execution and delivery of this Agreement and the other Finance
Documents, the execution and delivery of any Senior Debt Instruments, or any Permitted Senior Debt Hedging Instruments and the making of the Loans and extensions of credit thereunder. Notwithstanding anything in this Agreement or implied by law to
the contrary, the agreements, representations and warranties of Pledgor set forth herein shall terminate on the Discharge Date (other than those Senior Debt Obligations that under the terms of the Finance Documents survive the termination of the
Finance Documents). 
 7.17 Successions or Assignments. 

(a) Successors. This Agreement shall inure to the benefit of the successors and permitted assigns of the Secured Parties and such
successors or assigns shall have, to the extent of their interest, the rights of the applicable Secured Party hereunder. 
 (b)
Assignment. This Agreement is binding upon Pledgor and its successors and assigns. Other than through a transaction not prohibited by the Common Terms Agreement and the other Finance Documents, Pledgor is not entitled to assign its
obligations hereunder to any other Person without the written consent of the Security Trustee, and any purported assignment in violation of this provision shall be void. 

7.18 Headings Descriptive. 

The headings in this Agreement are for convenience of reference only and shall not constitute a part of this Agreement for any other purpose or
be given any substantive effect. 

  
 20 

 7.19 Entire Agreement. 

This Agreement, together with each other Finance Document is intended by the parties as a final expression of their agreement relating to the
subject matter herein contained and is intended as a complete and exclusive statement of the terms and conditions thereof. 
 7.20
Counterparts. 
 This Agreement may be executed in counterparts (and by different parties hereto in different counterparts), each of
which shall constitute an original, but all of which when taken together shall constitute a single contract. Delivery of an executed counterpart of a signature page of this Agreement by facsimile or portable document format (“pdf”) shall
be effective as delivery of a manually executed counterpart of this Agreement. 
 7.21 Limitation of Liability. 

No claim shall be made by any party against any other party or any of their Affiliates, directors, employees, attorneys or agents for any loss
of profits, business or anticipated savings, special or punitive damages or any indirect or consequential loss whatsoever in respect of any breach or wrongful conduct (whether or not the claim therefor is based on contract, tort or duty imposed by
law), in connection with, arising out of or in any way related to the transactions contemplated by this Agreement or the other Finance Documents or any act or omission or event occurring in connection therewith; and each party hereby waives,
releases and agrees not to sue upon any such claim for any such damages, whether or not accrued and whether or not known or suspected to exist in its favor. 

7.22 Third Party Beneficiaries. 

Nothing in this Agreement, expressed or implied, is intended or shall be construed to confer upon, or give to any Person, other than Pledgor,
the Security Trustee and the other Secured Parties, any security, rights, remedies or claims, legal or equitable, under or by reason hereof, or any covenant or condition hereof; and this Agreement and the covenants and agreements herein contained
are and shall be held to be for the sole and exclusive benefit of Pledgor, the Security Trustee and the other Secured Parties. 
 7.23
Non Recourse. 
 Except to the extent provided in Section 10.3 (Limitation on Recourse) of the Common Security and Account
Agreement, (a) the Non-Recourse Persons shall not be liable for any amount payable under this Agreement or any Finance Document and (b) no Secured Party shall seek a money judgment or deficiency or
personal judgment against any Non-Recourse Person for payment or performance of any obligation of the Loan Parties under this Agreement or the other Finance Documents. The provisions of Section 10.3
(Limitation on Recourse) of the Common Security and Account Agreement apply to this Agreement, mutatis mutandis. 

  
 21 

 7.24 Conflict. 

Notwithstanding anything to the contrary herein, in the case of any inconsistency between this Agreement and the Common Security and Account
Agreement, the Common Security and Account Agreement shall govern. 
 7.25 Amendment and Restatement. 

This Agreement amends, restates and supersedes the Initial Pledge Agreement in its entirety. 

[Remainder of page intentionally blank. Next page is signature page.] 

  
 22 

 IN WITNESS WHEREOF, the parties hereto, by their officers duly authorized, intending to be
legally bound, have caused this Agreement to be duly executed and delivered as of the date first above written. 
  

			
	 SECURITY TRUSTEE:
  

SOCIÉTÉ GÉNÉRALE

		
	By:	 	 /s/ Ellen Turkel

	Name:	 	Ellen Turkel
	Title:	 	Director

  
 [SIGNATURE
PAGE TO HOLDCO I PLEDGE AGREEMENT] 

 IN WITNESS WHEREOF, the parties hereto, by their officers duly authorized, intending to be
legally bound, have caused this Agreement to be duly executed and delivered as of the date first above written. 
  

			
	 PLEDGOR:
  

CHENIERE CCH HOLDCO I, LLC

		
	By:	 	 /s/ Lisa C. Cohen

	Name:	 	Lisa C. Cohen
	Title:	 	Treasurer

  
 [SIGNATURE
PAGE TO HOLDCO I PLEDGE AGREEMENT]

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00283-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00283-of-00352.parquet"}]]