Document:

Exhibit
10.10

 

AMENDMENT
NO. 3

TO THE

INTERNATIONAL HOUSE OF PANCAKES

EMPLOYEE STOCK OWNERSHIP PLAN

As Amended and Restated Effective as of January 1, 2001

 

 

WHEREAS, the IHOP Corp. (the “Company”) established
and maintains the International House of Pancakes Employee Stock Ownership
Plan, amended and restated effective as of January 1, 2001 (the “Plan”) for the
benefit of its eligible Employees;

 

WHEREAS, the Company desires to conform the Plan to
the applicable provisions of the Economic Growth and Tax Relief Reconciliation
Act of 2001(“EGTRRA”), to reflect the Internal Revenue Service (“IRS”) guidance
concerning deemed contributions to cafeteria plans under Section 125 under the
Internal Revenue Code (“Code”), the April 17, 2002 final and temporary regulations
from the IRS relating to age 70 1⁄2 minimum distributions under Section 401(a)(9)
of the Code and the Department of Labor regulations regarding disability
claims.

 

NOW, THEREFORE, the Plan as previously amended, is
further amended as follows:

 

1.             Effective January 1, 2002, Section
1 (Nature of the Plan) is amended by adding the following paragraph at the end
thereto:

 

The Plan contains provisions of the Economic Growth
and Tax Relief Reconciliation Act of 2001 (“EGTRRA”).  The EGTRRA provisions are intended as good faith compliance with
the requirements of EGTRRA and guidance issued thereunder.  Except as otherwise provided, the EGTRRA
provisions shall be effective January 1, 2002.

 

2.             Effective January 1, 2002, the
definition of “Compensation” in Section 2 (Definitions) is amended in its
entirety to read as follows:

 

	
  Compensation 

  	
   

  	
  The compensation of a Participant received from IHOP
  during the calendar year ending on or about the end of the Plan Year, as
  reported on the Participant’s Wage and Tax Statement (Form W-2), including
  amounts paid in cash as salary, wages, bonuses, overtime pay, tips and
  taxable fringe benefits as well as the amount of any elective deferrals made
  on a Participant’s behalf by IHOP to the 401(k) Plan for the Plan Year and
  any amounts withheld by IHOP pursuant to a “cafeteria plan” under Section 125
  of the Code, and effective January 1, 2001 any amounts not includible in an 

  

 

 

	
   

  	
   

  	
  Employee’s gross income by reason of Section
  132(f)(4) of the Code; but effective January 1, 2002, excluding any amount in
  excess of $200,000, as adjusted for increases in the cost of living pursuant
  to Section 401(a)(17) of the Code.  Effective
  January 1, 2002, any amounts withheld because of a “cafeteria plan” under
  Section 125 of the Code include any amounts not available to a Participant in
  cash in lieu of group health coverage because the Participant is unable to
  certify that he or she has other health coverage.  An amount will be treated as an amount under Section 125 only
  if the IHOP does not request or collect information regarding the
  Participant’s other health coverage as part of the enrollment process for the
  health plan.

  

 

3.             Effective January 1, 2002, the
definition of “Statutory Compensation” in Section 2 (Definitions) is amended in
its entirety to read as follows:

 

	
  Statutory Compensation 

  	
   

  	
  The
  total remuneration paid to an Employee by IHOP during the Plan Year for
  personal services rendered, including the amount of any elective deferrals
  made on his behalf by IHOP to the 401(k) Plan for the Plan Year and any
  amounts withheld by IHOP pursuant to a “cafeteria plan” under Section 125 of
  the Code, but excluding employer contributions to a plan of deferred
  compensation, amounts realized in connection with stock options and amounts
  which receive special tax benefits. Effective January 1, 2001 Statutory
  Compensation shall also include any amount not includible in an Employee’s
  gross income by reason of Section 132(f)(4) of the Code.  Effective January 1, 2002, any amounts
  withheld because of a “cafeteria plan” under Section 125 of the Code include
  any amounts not available to a Participant in cash in lieu of group health
  coverage because the Participant is unable to certify that he or she has
  other health coverage.  An amount will
  be treated as an amount under Section 125 only if the IHOP does not request
  or collect information regarding the Participant’s other health coverage as
  part of the enrollment process for the health plan.

  

 

4.             Effective January 1, 2002, Section
10(a)(1) is amended in its entirety to read as follows:

 

(1)           A Participant’s interest in his
Accounts shall become 100% vested and nonforfeitable without regard to his
Credited Service if he (A) is employed by IHOP or

 

2

 

an Affiliate on or after attaining 65,
(B) terminates Service by reason of Disability, (C) dies while
employed by IHOP or an Affiliate, or (D) elects to have cash dividends
payable attributable to shares of IHOP Stock held in his IHOP Stock Account
reinvested in IHOP Stock as provided in Section 13(a) (but only with respect to
such dividends); provided, however, that a Participant’s interest is his
Account attributable to Safe Harbor Contributions shall be 100% vested and
nonforfeitable at all times.

 

5.             Effective for determining required
minimum distributions for calendar years beginning on or after January 1, 2003,
Section 12(c) is amended by adding the following paragraph to the end thereto:

 

Notwithstanding any provision of the Plan to the
contrary, the minimum amount that must be distributed to the Participant as a
required minimum distribution in accordance with Section 12 (c) may not be less
than:

 

(1)                                    the Participant’s Capital Accumulation divided by
the applicable distribution period described in Section 1.401(a)(9)-9 of the
Treasury Regulations based on the Participant’s age as of his birthday in the
applicable calendar year; or,

 

(2)                                  if
the Participant’s sole designated beneficiary is his spouse, the Participant’s
Capital Accumulation divided by the number in the Joint and Last Survivor Table
set forth in Section 1.401(a)(9)-9 of the Treasury Regulations, based on the
Participant’s and the spouse’s ages as of their birthdays in the applicable
calendar year.

 

6.             Effective for all claims filed on
or after January 1, 2002, Section 18 (Claims Procedures) is restated in its
entirety to read as follows:

 

Section 18.  Claims
Procedures

 

(a)                                  Claims
Procedures.  A Participant or
Beneficiary (the “claimant”) who does not receive a distribution of benefits to
which he believes he is entitled to may present a claim to the Committee or
IHOP Corp.  Claims for benefits and
requests for reviews of denied claims for benefits shall be administered as
follows:

 

3

 

(1)                                  Authorized
Representative.  The claimant may
have an authorized representative to act on the claimant’s behalf in pursuing a
benefit claim or appeal of the denial of the benefit.  In order for a representative to be recognized as acting on
behalf of the claimant, the claimant must provide in writing to the Committee
the name, address and phone number of his authorized representative and a
statement that the representative is authorized to act in his behalf concerning
his claim for the benefit, and if applicable, an appeal of the denial of the
benefit.

 

(2)                                  Non-Disability
Claims.  Except as provided in
subsection (3) below, all claims for benefits under the Plan shall be submitted
to, and within 90 days thereafter decided by, in writing by the Committee.  If the Committee determines that an
extension of time for processing the claim is required, the Committee may
extend the date by which a decision is required to 180 days after the claim is
submitted provided that the Committee provides written notice of the extension
to the claimant prior to the termination of the initial 90-day period,
including the special circumstances requiring an extension of time and the date
by which the Committee expects to render a decision.

 

(3)                                  Disability
Claims.  All claims for benefits
under the Plan that are based upon the Participant’s Disability (each a
“Disability Claim”) shall be submitted to, and within 45 days thereafter
decided by, in writing by the Committee. 
If the Committee determines that an extension of time for processing the
Disability Claim is required, the Committee may extend the date by which a
decision is required to 75 days after the Disability Claim is submitted,
provided that the Committee provides written notice of the extension to the
claimant prior to the termination of the initial 45-day period, including the
special circumstances requiring an extension of time and the date by which the
Committee expects to render a decision. 
If the Committee determines that, due to matters beyond the control of
the Plan, a decision on a Disability Claim cannot be rendered within 75 days
after the Disability Claim is submitted, the Committee may extend the date by
which the decision is required to 105 days after the Disability Claim is filed,
provided that the Committee notifies the claimant, prior to the expiration of
the 75-day period, of the circumstances requiring the extension and the date as
of which the Plan expects to render a decision.  In the case of any extension of the 45-day or 75-day review
period, the notice of extension shall specifically explain the standards on
which entitlement to a benefit is based, the unresolved issues that prevent a
decision on the Disability Claim and the additional information needed to
resolve those issues, and the claimant shall be afforded at least 45 days
within which to provide the specified information.

 

(b)                                 Information
Provided Upon Denial of Claim (Including Disability Claims).  Written notice of the decision on each claim
(including any Disability Claim) shall be furnished reasonably promptly to the
claimant.  If the claim is wholly or
partially denied, such

 

4

 

written notice shall set forth (i) the specific reason
or reasons for the denial, (ii) reference to the specific Plan provisions on
which the denial is based, (iii) a description of any additional material or
information necessary for the claimant to perfect the claim and an explanation
of why such material or information is necessary, (iv) a description of the
Plan’s review procedures and the time limits applicable to such procedures,
including a statement of the claimant’s right to bring a civil action under
Section 502(a) of ERISA, following the denial of a claim on review, (v) in the
case of a denial of a Disability Claim, if an internal rule, guideline,
protocol, or other criterion was relied upon in making the adverse
determination, either the specific rule, guideline, protocol, or other similar
criterion, or a statement that such a rule, guideline, protocol, or other
similar criterion was relied upon in denying the claim and that a copy of such
rule, guideline, protocol, or other criterion will be provided free of charge
to the claimant upon request.

 

(c)                                  Review
of Denial of Non-Disability Claim. 
Except as provided in subsection (d) below, a claimant may request a
review by the Committee of a decision denying a claim in writing within 60 days
following receipt of the denial.  All
such reviews shall be decided in writing by the Committee within 60 days after
receipt of the request for review.  If
the Committee determines that an extension of time for processing the review is
required, the Committee may extend the date by which a decision is required to
120 days after the request for review is submitted provided that the Committee
provide written notice of the extension to the claimant prior to the
termination of the initial 60-day period, including the special circumstances
requiring an extension of time and the date by which the Committee expects to
render a decision.

 

5

 

(d)                                 Review
of Denial of Disability Claim.  A
claimant may request a review by the Board of Directors of a decision denying a
Disability Claim in writing within 180 days following receipt of the
denial.  All such reviews shall be
decided in writing by the Board of Directors within 45 days after receipt of
the request for review.  If the Board of
Directors determines that an extension of time for processing the review is
required, the Board of Directors may extend the date by which a decision is
required to 90 days after the request for review is submitted provided that the
Board of Directors provides written notice of the extension to the claimant
prior to the termination of the initial 45-day period, including the special circumstances
requiring an extension of time and the date by which the Board of Directs
expects to render a decision.  If the
Board of Directors cannot reach a decision about a claimant’s request for
review because the claimant has not submitted information requested by the
Board of Directors, the 45-days (or 45-day extension if applicable) shall be
tolled until the date on which the claimant responds to the request for
additional information.  The
Board of Directors may delegate its duty to review denied Disability Claims
hereunder provided that the person or entity to whom such duty is delegated
shall not be the member of the Committee who conducted the initial review or a
subordinate of that Committee member. 
Any review of a denied Disability Claim hereunder shall be without
deference to the Committee’s denial of the Disability Claim.

 

(e)                                  Review
Procedures for All Claims.  In
connection with a review of a denied claim for benefits (including a Disability
Claim), a claimant shall (i) have the opportunity to submit written comments,
documents, records, and other information relating to the claim for benefits,
and (ii) be provided, upon request and free of charge, reasonable access to,
and copies of, all documents, records, and other information relevant to the
claimant’s claim

 

6

 

for benefits.  The review of a denied claim shall take into
account all comments, documents, records, and other information submitted by
the claimant related to the claim, without regard to whether such information
was submitted or considered in the initial review of the claim.  If a claim is denied upon review, the
written notice of the denial shall specify (i) the specific reason or reasons
for the denial, (ii) reference to the specific Plan provisions upon which the
denial is based, and (iii) a statement that the claimant is entitled to
receive, upon request and free of charge, reasonable access to and copies of,
all documents, records and other information relevant to the claimant’s claim
for benefits.

 

(f)            Additional Review
Procedures for Disability Claims. 
If the denial of a Disability Claim upon review is based in whole or in
part on a medical judgment, the Board of Directors or its delegate shall
consult with a health care professional who has appropriate training and
experience in the field of medicine involved in the medical judgment.  Such professional shall be an individual who
is neither an individual who was consulted in connection with the initial
denial of the Disability Claim nor the subordinate of any such individual.  The Board of Directors or its delegate shall
provide for the identification of medical or vocational experts whose advice
was obtained on behalf of the Plan in connection with a denied Disability Claim
without regard as to whether the advice was relied upon in making the benefit
determination.  If an internal rule,
guideline or protocol, or other similar criterion was relied upon in denying a
Disability Claim upon review, the notice denying such claim upon review shall
set forth either the specific rule, guideline, protocol, or other similar
criterion, or a statement that such rule, guideline, protocol, or other
criterion was relied upon in denying the claim and that a copy of the rule,
guideline,

 

7

 

protocol, or other
similar criterion will be provided free of charge to the claimant upon
request.  Any notice denying a
Disability Claim upon review shall contain the following statement:  “You and your plan may have other voluntary
alternative dispute resolution options, such as mediation.  One way to find out what may be available is
to contact your local U.S. Department of Labor Office and your State insurance
regulatory agency.”

 

7.             Effective
January 1, 2002, Section 21 is amended by adding paragraph (d) as follows:

 

(d)           Effective
Date.  This paragraph (d) shall
apply for purposes of determining whether the Plan is a top-heavy plan under
Section 416(g) of the Code effective January 1, 2002.  This paragraph modifies Section 22 (a), (b) and (c) of the Plan.

 

(1)                                       Key
Employee.  Key employee means any
Participant or former Participant (including deceased Participants) who at any
time during the Plan Year that includes the determination date was an officer
of IHOP Corp. having annual compensation greater than $130,000 (as adjusted
under Section 416(i)(1) of the Code for Plan Years beginning after December 31,
2002), a five-percent owner of IHOP Corp., or a one-percent owner of IHOP Corp.
having annual compensation of more than $150,000.  For this purpose, annual compensation means compensation within
the meaning of Section 415(c)(3) of the Code. 
The determination of who is a key employee will be made in accordance
with Section 416(i)(1) of the Code and applicable regulations and other
guidance of general applicability issued thereunder.

 

(2)                                   Determination
of Account Balances.  This Section
21(d)(2) shall apply for purposes of determining the Account balances of
Participants as of the determination date.

 

(A)                            Distributions
during Year Ending on the Determination Date.  Account balances of a Participant as of a determination date
shall be increased by distributions made with respect to the Participant under
the Plan and any other plan aggregated with the Plan under Section 416(g)(2) of
the Code during the one-year period ending on the determination date.  The preceding sentence shall also apply to
distributions under a terminated plan, had it not been terminated, would have
been aggregated with the Plan under Section 416(g)(2)(A)(i) of the Code.  In the case of a distribution 

 

8

 

made for a reason other
than separation from Service, death or disability, this provision shall be
applied by substituting “five-year period” for “one-year period.”

 

(B)                               Participants
Not Performing Services During Year Ending on the Determination Date.  The Accounts of any individual who has not
performed services for IHOP Corp. during the one-year period ending on the
determination date shall not be taken into account.

 

(2)                                   Matching
Contributions.  IHOP matching
contributions shall be taken into account for purposes of satisfying the
minimum contribution requirements of Section 416(c)(2) of the Code and the
Plan.  IHOP matching contributions that
are used to satisfy the minimum contribution requirements shall be treated as
matching contributions for purposes of the actual contribution percentage test
and other requirements of Section 401(m) of the Code.

 

To record this Amendment No. 3 of the Plan, the Company
has caused it to be executed on this
           day of December,
2002.

 

 

	
   

  	
  IHOP CORP.

  
	
   

  	
   

  
	
   

  	
   

  
	
   

  	
  By

  	
   

  	
   

  

 

9QuickLinks
 -- Click here to rapidly navigate through this document

Exhibit 10.27.1  

CERTAIN CONFIDENTIAL INFORMATION CONTAINED IN THIS DOCUMENT, MARKED BY BRACKETS, HAS BEEN OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO
RULE 24b-2 OF THE SECURITIES EXCHANGE ACT OF 1934, AS AMENDED. 

 
 

AMENDED AND RESTATED SECOND AMENDMENT TO LEASE    
  

        THIS AMENDED AND RESTATED SECOND AMENDMENT TO LEASE ("Amendment") is made and entered into as of the
9th day of December, 2002, by and between CATELLUS DEVELOPMENT CORPORATION, a Delaware corporation ("Landlord"), and ALLOS
THERAPEUTICS, INC., a Delaware corporation ("Tenant"). 

 
 

R E C I T A L S:    
  

        A.    Landlord
and Tenant entered into that certain Office Lease dated as of April 4, 2001 (the "Original Lease"), as
amended by that certain First Amendment to Lease and Commencement Date Memorandum dated as of November 1, 2002 ("First Amendment"), and that
certain Second Amendment to Lease dated November 12, 2002 ("Second Amendment"), whereby Tenant leased certain office space in the building
located at 11080 CirclePoint Road in Westminster, Colorado. The Original Lease, as amended by the First Amendment and Second Amendment, is referred to herein as the
"Lease." 

        B.    By
this Amendment, Landlord and Tenant desire amend and restate the Second Amendment in its entirety. 

        C.    Unless
otherwise defined herein, capitalized terms as used herein shall have the same meanings as given thereto in the Lease. 

        NOW,
THEREFORE, in consideration of the foregoing recitals and the mutual covenants contained herein, and for other good and valuable consideration, the receipt and sufficiency of which
are hereby acknowledged, the parties hereto agree as follows: 

 
 

A G R E E M E N T:    
  

        1.    The Existing Premises.    Landlord currently leases to Tenant that certain office space containing 31,248
rentable square feet located on the second (2nd) floor of the Building and known as Suite 200 (the "Existing Premises"). 

        2.    Expansion of the Premises.    That certain space located on the ground floor of the Building consisting of
approximately 12,129 rentable square feet, as outlined on the floor plan attached hereto as Exhibit A and made a part hereof, is referred to herein as the "Expansion
Space." Tenant shall lease the Expansion Space effective as of January 1, 2003 (the "Expansion Commencement Date").
Accordingly, effective upon the Expansion Commencement Date, the Existing Premises shall be increased to include the Expansion Space. Such addition of the Expansion Space to the Existing Premises
shall, effective as of the Expansion Commencement Date, increase the number of rentable square feet leased by Tenant in the Building to a total of 43,377 rentable square feet, subject to verification
pursuant to Section 3 below. Effective as of the Expansion Commencement Date, all references in the Lease to the "Premises" shall mean and refer to the Existing Premises as expanded by the
Expansion Space. The period from the Expansion Commencement Date through the Expiration Date is referred to herein as the "Expansion Term." 

        3.    Verification of Rentable Square Footage.    The rentable square footage of the Expansion Space shall be subject
to verification in accordance with the provisions of Section 2.1 of the Original Lease, except that Landlord shall cause its space measurement consultant to provide such verification within
thirty (30) days following the Expansion Commencement Date. If such verification results in a rentable square footage of the Expansion Space that is different than that set forth in
Section 2 above, then the parties shall further amend the Lease to modify all amounts, percentages and figures appearing or 

 

referred to in this Amendment to conform to such corrected rentable square footage (including, without limitation, the Base Rent, and Tenant's Percentage Share and the TI Allowance). 

        4.    Base Rent.    During the Expansion Term, and in addition to the Base Rent for the Existing Premises, Tenant
shall pay Base Rent for the Expansion Space as follows (although Base Rent for the Existing Premises and the Expansion Space are separately identified, such amounts shall be a single and
non-severable rental obligation): 

	Period of

Expansion Term
	 	Annual Base Rent Per Rentable

Square Foot
	 	Annual Base Rent
	 	Monthly Base Rent

	1-12

(1/01/03 - 12/31/03)	 	[*]	 	[*]	 	[*]
	

13-15

(1/01/04 - 3/31/04)	
 	

[*]	
 	

[*]	
 	

[*]
	

16-45

(4/01/04 - 9/30/06)	
 	

[*]	
 	

[*]	
 	

[*]
	

46-70

(10/1/06 - 10/31/08)	
 	

[*]	
 	

[*]	
 	

[*]

        5.    Tenant's Percentage Share.    Commencing on July 1, 2003, and continuing thereafter during the Expansion
Term, Tenant's Percentage Share shall be increased to 28.72%. The parties acknowledge that Tenant shall have no obligation to pay Real Property Taxes and Operating Expenses attributable to the
Expansion Space during the period from the Expansion Commencement Date through June 30, 2003. 

        6.    Exclusion of Variable Operating Expenses.    Operating Expenses attributable to the Expansion Space shall
exclude those Operating Expenses that vary with occupancy, such as janitorial expenses and utility costs (other than those attributable to the Common Facilities), until the Tenant Improvements (as
defined in Exhibit B) are substantially completed in all or any portion of the Expansion Space. 

        7.    Letter of Credit.    The schedule of Adjustment Dates for reducing the Stated Amount of the Letter of Credit as
set forth in Section 4.4.1 of the Original Lease is deleted and the following is substituted therefor: 

	Anniversary of Commencement Date
	 	Total Stated Amount

	5th (10/01/06)	 	[*]
	6th (10/01/07)	 	[*]
	7th (10/01/08)	 	[*]

        Notwithstanding
anything to the contrary contained in Section 4.4.1 of the Original Lease, if Tenant gives Landlord written notice that Tenant's net income for any consecutive
twelve (12)-month period exceeds [*], together with evidence reasonably acceptable to Landlord verifying that such net income threshold has been met (and a certification from
Tenant's Chief Financial Officer that all such evidence is true and correct), then Landlord shall return the Letter of Credit to Tenant; provided, however, in no event shall Landlord be obligated to
return the Letter of Credit to Tenant at any time an Event of Default exists or any circumstance exists that would, with notice or lapse of time, or both, constitute an Event of Default. 

        8.    Cash Security Deposit.    The date by which Tenant shall deposit with Landlord the cash Security Deposit
pursuant to Section 4.4.2 of the Original Lease is extended from the sixth (6th) anniversary of the Rent Commencement Date to the seventh (7th) anniversary of the
Commencement Date (10/1/08); provided, however, if the Letter of Credit is released prior to the seventh (7th) anniversary of the Commencement Date pursuant to the provisions of
Section 7 above, then Tenant shall, concurrently 

2

 

with Landlord's delivery of the Letter of Credit to Tenant, deliver the cash Security Deposit to Landlord. 

        9.    Tenant Improvements.    The Tenant Improvements (as defined in Exhibit B) in the Expansion Space shall be
installed and constructed in accordance with the terms of the Tenant Work Letter attached hereto as Exhibit B and made a part hereof. The parties acknowledge that there is no required time
schedule to construct the Tenant Improvements, and Tenant shall, subject to Landlord's reasonable approval, be entitled to designate with the Tenant Improvements are to be constructed. Tenant
acknowledges that construction of the Tenant Improvements may occur during the Expansion Term and that the performance of such work shall not be deemed a constructive eviction nor shall Tenant be
entitled to any abatement of Rent in connection therewith. In addition, Landlord shall not be liable for any damage to property, injury to persons or damage to Tenant's business caused by the
construction of the Tenant Improvements during the Expansion Term. 

        10.    Parking.    During the Expansion Term, Tenant shall rent from Landlord an additional forty-nine
(49) parking spaces for use in the Building's parking facility. Tenant's rental and use of such additional parking spaces shall be in accordance with, and subject to, all provisions of
Section 2.4 of the Original Lease. 

        11.    Subletting.    The limitation on the number of subparcels under clause (viii) of Section 18.1 of
the Original Lease shall only apply to the Existing Premises, and the number of subparcels within the Expansion Space shall be subject to Landlord's reasonable approval. 

        12.    Brokers.    Each party represents and warrants to the other that no broker, agent or finder negotiated or was
instrumental in negotiating or consummating this Amendment other than Equis Corporation and CB Richard Ellis ("Brokers"). Landlord shall pay a brokerage
commission to Brokers in accordance with separate agreements between and Landlord and Brokers. Subject to the foregoing, each party agrees to defend, indemnify and hold harmless the other party from
and against any claim for a commission or finder's fee by any person or entity who claims or alleges that they were retained or engaged by the indemnifying party or at the request of such party in
connection with this Amendment. 

        13.    Tenant Representations.    Each person executing this Amendment on behalf of Tenant represents and warrants to
Landlord that, and Tenant shall, at Landlord's request, provide Landlord with evidence that: (a) Tenant has full right and authority to enter into this Amendment and to perform all of Tenant's
obligations hereunder; and (b) each person signing this Amendment on behalf of Tenant is duly and validly authorized to do so. 

        14.    Second Amendment.    This Amendment amends and restates the Second Amendment in its entirety, such that the
provisions in the Second Amendment shall have no effect. 

        15.    No Further Modification.    Except as set forth in this Amendment, all of the terms and provisions of the Lease
shall apply with respect to the Expansion Space and shall remain unmodified and in full
force and effect. Effective as of the date hereof, all references to the "Lease" shall refer to the Lease as amended by this Amendment. 

3

 

        IN
WITNESS WHEREOF, this Amendment has been executed as of the day and year first above written. 

	 	 	"Landlord":
	

 	
 	

CATELLUS DEVELOPMENT CORPORATION,

a Delaware corporation
	

 	
 	

By:	
 	

Catellus Commercial Development Corporation,

a Delaware corporation

Its: Agent
	

 	
 	

By:	
 	

/s/ Ray C. Pittman

	 	 	 	 	Name:	 	Ray C. Pittman

	 	 	 	 	Its:	 	Senior V.P.

	

 	
 	

"Tenant":
	

 	
 	

ALLOS THERAPEUTICS, INC.,

a Delaware corporation
	

 	
 	

By:	
 	

/s/ Michael E. Hart

	 	 	 	 	Name:	 	Michael E. Hart.

	 	 	 	 	Its:	 	President/CEO

	

 	
 	

By:	
 	

        

	 	 	 	 	Name:	 	        

	 	 	 	 	Its:	 	        

4

 
 

EXHIBIT A    
    
    OUTLINE OF EXPANSION SPACE    
  

        [graphic] 

  

 
 

EXHIBIT B    
    
    TENANT WORK LETTER    
  

        This Work Letter ("Work Letter") is attached to the Amendment as Exhibit B and incorporated into the
Amendment by reference. Capitalized terms used herein and not defined herein shall have the respective meanings set forth in the Lease. 

        1.    Landlord's Work.    Landlord has constructed the Building in accordance with the plans and specifications
described in Schedule I attached hereto. 

        2.    Tenant Improvements.    

        2.1    TI Allowance.    Tenant shall be entitled to a one-time tenant improvement allowance (the
"TI Allowance") in the amount of [*] per rentable square foot of the Expansion Space for the costs relating to the initial
design and construction of Tenant's improvements that are permanently affixed to the Expansion Space (the "Tenant Improvements"). In no event shall
Landlord be obligated to make disbursements pursuant to this Work Letter in a total amount which exceeds the TI Allowance. Provided the Tenant Improvements are constructed and are consistent with the
improvements in the Existing Premises, Tenant shall be entitled to a credit against Base Rent first payable for the Expansion Space in an amount equal to any unused portion of the TI Allowance. 

        2.2    Disbursement of the TI Allowance.    Except as otherwise set forth in this Work Letter, the TI Allowance shall
be disbursed by Landlord (each of which disbursements shall be made pursuant to Landlord's disbursement process), only for the following items and costs (collectively, the "TI
Allowance Items"): (a) payment of the fees of the "Architect" and the "Engineers," as those terms are defined in Section 2.3 of this Work Letter, and payment of
the fees incurred by, and the cost of documents and materials supplied by, Landlord and Landlord's consultants in connection with the preparation and review of the "Working Drawings," as that term is
defined in Section 2.3 of this Work Letter; (b) the payment of plan check, permit and license fees relating to construction of the Tenant Improvements; (c) the cost of
construction of the Tenant Improvements; (d) the cost of any changes in the base, shell and core of the Building when such changes are required by the Working Drawings (including if such
changes are due
to the fact that such work is prepared on an unoccupied basis) or are otherwise required by Applicable Law as a result of the construction of the Tenant Improvements, such cost to include all direct
architectural and/or engineering fees and expenses incurred in connection therewith; (e) the cost of any changes to the Working Drawings or Tenant Improvements required by Applicable Law;
(f) sales and use taxes and/or applicable fees; (g) "Landlord's Supervision Fee," as that term is defined in Section 2. 10 of this Work Letter; (h) all other costs to be
expended by Landlord in connection with the construction of the Tenant Improvements; and (i) one-half (1/2) of the costs of the demising walls between the Expansion
Space and any other tenant space in the Building's ground floor lobby. 

        2.3    Building Specifications.    Landlord may establish specifications for the Building-standard components to be
used in the construction of the Tenant Improvements in the Expansion Space (collectively, the "Building Specifications"), which shall be available to
Tenant upon request. Tenant shall utilize materials and finishes that comply with the Building Specifications and Tenant shall not substitute any such materials or finishes without Landlord's prior
written consent. Landlord may make changes to the Building Specifications from time to time. 

        2.3.1    Selection of Architect/Working Drawings.    Conditioned upon Landlord's reasonable approval of a contract for
services, Tenant shall retain Ware Malcomb Architects or such other architect reasonably acceptable to Landlord (the "Architect") to prepare the
"Working Drawings," as that term is defined in this Section 2.3.1 below. Landlord shall retain Landlord's designated engineering consultants (the
"Engineers") to prepare all plans and engineering working drawings relating to the structural, mechanical, HVAC/lifesafety, electrical, plumbing, 

1

 

and sprinkler work in the Expansion Space. The plans and drawings to be prepared by the Architect hereunder shall be known collectively as the "Working
Drawings" and the plans and drawings to be prepared by the Engineers hereunder shall be known collectively as the "Engineering
Drawings." Notwithstanding that Landlord has retained the Engineers to prepare the Engineering Drawings and that Landlord shall review the Working Drawings required hereunder,
Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in the Working Drawings or the Engineering Drawings. 

        2.3.2    Selection of Contractor.    Landlord shall retain a contractor
("Contractor") designated by Landlord and reasonably approved by Tenant to construct the Tenant Improvements. The Contractor shall subcontract with
Landlord's designated subcontractors for any and all mechanical, electrical plumbing, HVAC/lifesafety, and sprinkler systems. Tenant shall be permitted to participate with Landlord in the process of
selecting the Contractor. 

        2.4    Final Space Plan.    Tenant and the Architect shall prepare the final space plan for Improvements in the
Expansion Space (collectively, the "Final Space Plan"), which Final Space Plan shall include a layout and designation of all offices, rooms and other
partitioning, their intended use, and equipment to be contained therein, and shall deliver the Final Space Plan to Landlord for Landlord's approval or reasonable disapproval, which approval or
reasonable disapproval shall be delivered by Landlord to Tenant no later than five (5) business days after Landlord's receipt of such Final Space Plan. If Landlord reasonably disapproves of any
portion of the Final Space Plan, the parties shall meet, within
five (5) days after Landlord's disapproval, to agree upon revisions to be made to the Final Space Plan to meet the reasonable satisfaction of Landlord. The Architect shall then revise the Final
Space Plan to the form agreed upon in such meeting and Landlord shall then approve or reasonably disapprove the revised Final Space Plan in writing no later than five (5) business days after
Landlord's receipt of such revised Final Space Plan. If Landlord shall again reasonably disapprove the revised Final Space Plan, the parties will revise and review the Final Space Plan again in
accordance with the procedure set forth above until Landlord's reasonable, approval is obtained. 

        2.5    Final Working Drawings.    Tenant and the Architect shall complete the architectural drawings for the Expansion
Space, and the Architect shall compile a fully coordinated set of architectural working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable
permits (collectively, the "Final Working Drawings") and shall submit the same to Landlord for Landlord's approval or reasonable disapproval, which
approval or reasonable disapproval shall be delivered by Landlord to Tenant no later than five (5) business days after Landlord's receipt of such Final Working Drawings. If Landlord reasonably
disapproves of any portion of the Final Working Drawings, the parties shall meet, within five (5) days after Landlord's disapproval, to agree upon revisions to be made to the Final Working
Drawings to meet the reasonable satisfaction of Landlord. The Architect shall then revise the Final Working Drawings to the form agreed upon in such meeting. Landlord shall then approve or reasonably
disapprove the revised Final Working Drawings no later than five (5) business days after Landlord's receipt of such revised Final Working Drawings. If Landlord shall again reasonably disapprove
the revised Final Working Drawings, the parties will revise and review the Final Working Drawings again in accordance with the procedure set forth above until Landlord's reasonable approval is
obtained. 

        2.6    Approved Working Drawings.    The Final Working Drawings approved by Landlord and Tenant and the Engineering
Drawings shall be referred to herein collectively as (the "Approved Working Drawings") and Tenant shall submit the same to the appropriate governmental
entities for all applicable building permits necessary to allow the Contractor to pull the applicable building permits and commence and fully complete the construction of the Tenant Improvements (the 

2

 

"Permits"). If Tenant desires any change, modification or alteration in the Approved Working Drawings, Tenant must first obtain the prior written
consent of Landlord. Prior to commencing any change requested by Tenant to the Approved Working Drawings, Landlord shall prepare and deliver to Tenant, for Tenant's approval, a change order
("Change Order") setting forth the additional time required to perform the change and the total cost of such change, which shall include associated
architectural, engineering and Contractor's fees. If Tenant fails to approve such Change Order in writing within two (2) business days after such delivery by Landlord, Tenant shall be deemed to
have withdrawn the Change Order and Landlord shall not proceed to perform the change but will continue with construction in accordance with the Approved Working Drawings. 

        2.7    Time Deadlines.    Tenant shall cooperate with (i) the Architect, the Engineers, and Landlord to
complete all phases of the Working Drawings, the Engineering Drawings and the permitting process, and (ii) the Contractor, for approval of the "Cost Proposal," as that term is defined in
Section 2.8 below, in accordance with the dates set forth herein. Tenant shall meet with Landlord on a weekly basis to discuss Tenant's progress in connection with the same. The applicable
dates for approval of items, plans
and drawings and selection of a contractor as described in this Work Letter are referred to herein as the "time deadlines." Tenant agrees to comply with
the time deadlines. 

        2.8    Cost Proposal.    After the Approved Working Drawings are approved by Landlord and Tenant, Landlord shall
provide Tenant with a cost proposal in accordance with the Approved Working Drawings, which cost proposal shall include, as nearly as possible, the cost of all TI Allowance Items to be incurred by
Tenant in connection with the construction of the Tenant Improvements (the "Cost Proposal"). Landlord does not guaranty the accuracy of the Cost
Proposal. Notwithstanding the foregoing, portions of the cost of the Tenant Improvements may be delivered to Tenant as such portions of the Tenant Improvements are priced by Contractor (on an
individual item-by-item or trade-by-trade basis), even before the Approved Working Drawings are completed (the "Partial Cost
Proposal"). Tenant shall either (i) approve and deliver the Cost Proposal to Landlord within five (5) business days of the receipt of the same (or, as to a
Partial Cost Proposal, within two (2) business days of receipt of the same), or (ii) notify Landlord within five (5) business days after Tenant's receipt of the Cost Proposal (or
Partial Cost Proposal, as the case may be) that Tenant desires to revise the Approved Working Drawings to reduce the amount of the Cost Proposal (or Partial Cost Proposal, as the case may be), in
which case such changes shall be made to the Approved Working Drawings only in accordance with Section 2.7 above and the revised Working Drawings shall be provided to the Contractor for
repricing whereupon Landlord shall revise the Cost Proposal (or Partial Cost Proposal, as the case may be) for Tenant's approval. This procedure shall be repeated until the Cost Proposal (or Partial
Cost Proposal, as the case may be) is approved by Tenant. The date by which Tenant has approved the Cost Proposal, or the last Partial Cost Proposal, as the case may be, shall be known hereafter as
the "Cost Proposal Delivery Date." The total of all Partial Cost Proposals, if any, shall be known as the Cost Proposal. 

        2.9    Over-Allowance Amount.    The amount that is equal to the difference between (i) the amount
of the Cost Proposal and (ii) the amount of the TI Allowance (less any portion thereof already disbursed by Landlord, or in the process of being disbursed by Landlord, on or before the Cost
Proposal Delivery Date that is not otherwise included within the Cost Proposal) shall be referred to herein as the "Over-Allowance Amount."
Tenant shall pay to Landlord (a) one-half (1/2) of such Over-Allowance Amount no later than ten (10) days after the Cost Proposal Delivery Date and
(b) the other one-half (1/2) of such Over-Allowance Amount within ten (10) days after Landlord gives Tenant written notice that the construction of
the Tenant Improvements is completed. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any then remaining portion of the TI Allowance, and such
disbursement shall be pursuant to 

3

 

the same procedure as the TI Allowance. In the event that after the Cost Proposal Delivery Date, any revisions, changes, or substitutions shall be made to the Construction Drawings or the Tenant
Improvements, any additional costs which arise in connection with such revisions, changes or substitutions shall be paid by Tenant to Landlord as an addition to the Over-Allowance Amount
as follows: (1) one-half (1/2) of such additional amount within five (5) days after Landlord's invoice therefor and (2) the remaining
one-half (1/2) of such additional amount within five (5) days following Tenant's receipt of Landlord's written notice that the work to which the change order applies
is complete. In addition, upon Landlord's determination of the actual costs incurred by or on behalf of Landlord for the TI Allowance Items, Tenant shall pay Landlord the amount, if any, by which such
actual costs exceed the sum of the TI Allowance and the Over-Allowance Amount within fifteen (15) days after being billed therefor, or Landlord may, at its election, require that
Tenant deposit with Landlord the full amount of such excess prior to Landlord's delivery of the Expansion Space to Tenant. No portion
of the TI Allowance shall be used to pay Tenant or Tenant's agents, contractors or employees, unless and until Landlord's contractors and any other persons and entities employed by or under contract
with Landlord have been paid in full. 

        2.10    Landlord Supervision.    Landlord shall independently retain Contractor to construct the Tenant Improvements
in accordance with the Approved Working Drawings and the Cost Proposal and Landlord shall supervise the construction by Contractor, and Tenant shall pay a construction supervision and management fee
(the "Landlord Supervision Fee") to Landlord (or its agent) in an amount equal to the product of (i) four percent (4%) and (ii) the
Over-Allowance Amount. 

        2.11    Contractors' Warranties and Guaranties.    Landlord hereby assigns to Tenant all warranties and guaranties by
Contractor relating to the Tenant Improvements, and Tenant hereby waives all claims against Landlord relating to, or arising out of the construction of, the Tenant Improvements. 

        3.    Completion of the Tenant Improvements.    

        3.1    Intentionally Omitted.    [Note: Sections 2.4 and 2.5 already provide for
turn-around times for Landlord.] 

        3.2    Intentionally Omitted.    

        3.3    Tenant's Entry Into the Expansion Space Prior to Substantial Completion.    Provided that Tenant and its agents
do not interfere with, or delay, Contractor's work in the Building and the Expansion Space, Contractor shall allow Tenant access to the Expansion Space prior to the substantial completion of the
Expansion Space for the purpose of Tenant installing overstandard equipment or fixtures (including Tenant's data and telephone equipment) in the Expansion Space. Prior to Tenant's entry into the
Expansion Space as permitted by the terms of this Section 3.3, Tenant shall submit a schedule to Landlord and Contractor, for their approval, which schedule shall detail the timing and purpose
of Tenant's entry. Tenant shall hold Landlord harmless from and indemnify, protect and defend Landlord against any loss or damage to the Building or Expansion Space and against injury to any persons
caused by Tenant's actions pursuant to this Section 3.3. 

        3.4    Tenant's Representative.    Tenant has designated Rhonda Gardner as its sole representatives with respect to
the matters set forth in this Work Letter, each of whom shall have full authority and responsibility to act on behalf of the Tenant as required in this Work Letter. 

        3.5    Landlord's Representative.    Landlord has designated Gardiner Hammond as its sole representatives with respect
to the matters set forth in this Work Letter, each of whom, until further notice to Tenant,
shall have full authority and responsibility to act on behalf of the Landlord as required in this Work Letter. 

4

 

        3.6    Time of the Essence.    Unless otherwise indicated, all references herein to a "number of days" shall mean and
refer to calendar days. In all instances where Tenant is required to approve or deliver an item, if no written notice of approval is given or the item is not delivered within the stated time period,
at Landlord's sole option, at the end of said period the item shall automatically be deemed approved or delivered by Tenant and the next succeeding time period shall commence. 

        3.7    Tenant's Lease Default.    Notwithstanding any provision to the contrary contained in this Lease, if an Event
of Default as described in Section 16 of the Lease or this Work Letter has occurred at any time on or before the substantial completion of the Expansion Space or if a circumstance exists that
with the giving of notice, the lapse of time, or both, would constitute an Event of Default under the Lease, then (i) in addition to all other rights and remedies granted to Landlord pursuant
to this Lease, Landlord shall have the right to withhold payment of all or any portion of the TI Allowance and/or Landlord may cause Contractor to cease the construction of the Expansion Space, and
(ii) all other obligations of Landlord under the terms of this Work Letter shall be suspended until such time as such default is cured pursuant to the terms of this Lease. 

        3.8    Tenant's Agents.    All of Tenant's agents, contractors, and subcontractors performing work in, or in
connection with, the Expansion Space (collectively as "Tenant's Agents"), shall be subject to Landlord's reasonable approval and, if deemed necessary by
Landlord to maintain harmony among other labor at the real property or if required by law or any agreement to which Landlord is bound, shall be union labor. 

        3.9    Tenant's Architect's Insurance.    Prior to Tenant's Architect performing any services in connection with the
Tenant Improvements, the Final Space Plan, or the Working Drawings, Tenant shall deliver to Landlord certificates evidencing that Tenant's Architect has in force, with insurance companies reasonably
acceptable to Landlord, (i) Professional Liability Insurance with limits of not less than Five Million Dollars ($5,000,000) per claim and annual aggregate, with a retention of not more than
Fifty Thousand Dollars $50,000) per claim and an inception date or a retroactive date coinciding with or prior to the earlier of the Effective Date or the date of first performance of Tenant's
Architect's services, (ii) Workers Compensation Insurance as required by state and federal statutes with Employer's Liability Insurance with limits of not less than One Million Dollars
($1,000,000) for bodily injury by accident and One Million Dollars ($1,000,000) for bodily injury by disease, (iii) Commercial General Liability Insurance in the amount of not less than One
Million Dollars $1,000,000) per occurrence, One Million Dollars ($1,000,000) annual general aggregate, and (iv) Commercial Automobile Liability Insurance for all owned and non-owned
automobiles utilized in connection with the services performed under the Tenant's Architect contract in the amount of not less than One Million Dollars ($1,000,000) combined single limit for bodily
injury and property damage combined. All such insurance required by this Section 3.9 shall be maintained for the entire period during which services are performed under Tenant's Architect's
contract, with the exception of the Professional Liability Insurance policy which
shall be maintained in force for at least one (1) year following substantial completion of the Tenant Improvements. Thereafter, during the second (2nd) and third
(3rd) years following substantial completion of the Tenant Improvements, Tenant's Architect shall maintain Professional Liability Insurance with limits of not less than One Million
Dollars ($1,000,000.00) annual aggregate, on a claims made basis, during such second (2nd) and third (3rd) years after substantial completion of the Tenant Improvements, so
long as such insurance is reasonably available under standard policies at rates comparable to those in effect as of the date of such Substantial Completion. Landlord shall be named as an additional
insured on all required Commercial General Liability policies of Tenant's Architect, and the required certificate of insurance shall include an additional insured endorsement ISO form number CG 20 10
11 85, or equivalent, evidencing such additional insured 

5

 

status. All insurance of Tenant's Architect will be primary as respects any insurance of Landlord, which insurance shall be non-contributing. 

        3.10    Insurance Requirements.    All of Tenant's Agents shall carry liability and Products and Completed Operation
Coverage insurance, each in amounts not less than One Million Dollars ($1,000,000.00) per incident, One Million Dollars ($1,000,000.00) in aggregate, and in form and with companies as are required to
be carried by Tenant as set forth in Section 9.2 of the Lease, and the policies therefor shall insure Landlord and Tenant, as their interests may appear, as well as Landlord's contractor, and
shall name as additional insureds all mortgagees of the real property or any other party designated by Landlord. All insurance maintained by Tenant's Agents shall preclude subrogation claims by the
insurer against anyone insured thereunder. Such insurance shall provide that it is primary insurance as respects the Landlord and that any other insurance maintained by Landlord is excess and
noncontributing with the insurance required hereunder. 

6

  

 
 

SCHEDULE I TO EXHIBIT B    
    
    BUILDING PLANS AND SPECIFICATIONS    
    
    WESTMINSTER    
    
    BASE BUILDING CORE AND SHELL    
  

	

Parking Stalls:	
 	

Parking is provided at 4.1 spaces per 1,000 square feet of rentable building area.
	

Parking Lot Lighting:	
 	

Parking lot lighting is provided, designed to supply an average to minimum ratio of approximately 1.0 foot candles/SF.
	

Sitework:	
 	

Asphalt concrete paving in all traffic and parking areas, concrete curb and gutter per approved development plans.
	

Landscaping:	
 	

Landscape planting materials and irrigation of all planting areas per approved development plans.
	

Building Structure:	
 	

Precast concrete frame with precast concrete floor and roof structure and approximately 4-inch concrete topping slab.
	

Floor Loading Criteria:	
 	

Live load is approximately 50 psf in general office area, with approximately 100 psf at corridor and interior office area immediately adjacent to corridor. Partition load is approximately 20 psf.
	

Ceiling Heights:	
 	

Clear ceiling heights are approximately 12'-2" feet at ground floor tenant areas, and approximately 9'-2" at floors 2, 3, 4 and 5 tenant areas. Typical structure to structure clearance is approximately 14.5 feet at ground floor 14'-8" from floor to
bottom of "T" at ground floor, and 11'-8" approximately 11. 5 feet from floor to bottom of "T" at floors 2, 3, 4 and 5. Clearances may be 12 inches less at beam locations.
	

Building Skin:	
 	

Precast architectural concrete spandrel panels with continuous glazing in between. Full height glazing at most locations. See elevation drawings for detail.
	

Roofing:	
 	

60 mil EPDM roof membrane, ballasted, over 2.6" rigid polyisocyanruate board. R-value of 19.
	

Perimeter Walls:	
 	

Perimeter, exterior walls to be insulated only, no drywall.
	

Core Service Areas:	
 	

1. Sound attenuation is provided to meet NC35 levels.

2. Janitor's closet provided on each floor.

3. Finished doors provided for all service rooms.

4. Door frames to be anodized aluminum for all core doors.

5. One drinking fountain location each floor, with two fountains, one meeting ADA requirements.
	

Rest Rooms:	
 	

Rest rooms to have ceramic tile on floors, and full height on wet walls. Toilet partitions to be ceiling hung stainless steel. Vanity tops to be granite. Rest rooms to be ADA compliant.
	

Shower Facilities:	
 	

Ground floor restrooms to include two shower stalls each in men's and women's. One shower stall in each to be ADA compliant.
	
 	
 	

 

1

 

	

Telephone Room:	
 	

Main telephone/fiber optic room provided at ground floor, approximately 20 feet by 10 feet. Conduit to be stubbed into room for telephone and 3 possible fiber optic providers. Approximately 6 foot by 9 foot communications rooms provided on floors 2,
3, 4 and 5.
	

Elevators:	
 	

Hydraulic elevators, 3,500 lb. capacity provided. Interior cab height to be approximately 10 feet, with suspended ceiling at approximately 9 feet. Finishes will be compatible with main lobby. Freight elevator to be supplied with protective blankets.
Waiting time will be average of 27-29 seconds, with 5 minute handling capacity of 13% of building population (upper floors only). Elevators to be ADA compliant, and provided with emergency telephones.
	

Fire Protection:	
 	

Complete fire sprinkler system in accordance with applicable codes for office occupancy. Fireproofing of the Building's structural steel as specified on the structural plans for the Building as approved by the City of Westminster (a copy of which
plans Tenant acknowledges receiving).
	

Plumbing Systems:	
 	

Complete plumbing system for domestic water service, sanitary sewer service, and roof drainage. Water and sanitary systems will be accessible to tenant areas for future connections for convenience sinks and other uses.
	

HVAC:	
 	

HVAC system is provided with rooftop units, total capacity approximately 460 tons, of approximately 350 sf per ton. Primary trunk ducts and exterior zone VAV boxes provided at approximately 1 per 1,100 SF. Exterior zone VAV boxes are provided with
electric reheat. No distribution ducting or diffusers are included at these exterior zone boxes.
	

 	
 	

Energy management system provided, with remote computer monitoring capability. Tenant metering capability also included in system.
	

 	
 	

HVAC Design criteria for cooling load allowed include the following:
	

 	
 	

2 watts per SF for lighting;

1.5 watts per SF for office equipment;

150 SF per person.
	

Electrical Service:	
 	

The building is provided with primary electrical service, 277/480 volts, 3 phase, with main disconnects in the main electrical room on the first floor. Electrical distribution panel rooms are provided two per floor adjacent to stairwells.
	

 	
 	

Electrical service will provide total capacity of 27 watts per square foot, generally allocated as follows:
	

 	
 	

15 watts per SF for HVAC loads;

3 watts per SF for lighting;

6.5 watts per SF for tenant equipment loads;

2.5 watts per SF spare power;

A pad area for a future generator to be included in the building shell.
	

Fire Alarm:	
 	

Fire alarm panel is provided, including fire alarm devices as required by code in core and common areas.
	
 	
 	

 

2

 

	

Security	
 	

A card access system to be provided at the main entry doors of the building. Elevator card access also to be available based on tenant needs (but at Tenant's sole cost and expense).

[*]
= CERTAIN CONFIDENTIAL INFORMATION CONTAINED IN THIS DOCUMENT, MARKED BY BRACKETS, HAS BEEN OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION
PURSUANT TO RULE 24b-2 OF THE SECURITIES EXCHANGE ACT OF 1934, AS AMENDED. 

3

QuickLinks

AMENDED AND RESTATED SECOND AMENDMENT TO LEASE

R E C I T A L S

A G R E E M E N T

EXHIBIT A OUTLINE OF EXPANSION SPACE

EXHIBIT B TENANT WORK LETTER

SCHEDULE I TO EXHIBIT B BUILDING PLANS AND SPECIFICATIONS WESTMINSTER BASE BUILDING CORE AND SHELL

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00049-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00049-of-00352.parquet"}]]