Document:

Letter Agreement

 Exhibit 10.9 
 CHUY’S OPCO, INC. 
 c/o Goode Partners LLC 

667 Madison Avenue, 21st Floor 
 New York, New York 10021 
 November 7, 2006 

Three Star Management, Ltd. 
 1623 Toomey Road 
 Austin, Texas 78704 

Attention: Michael R. Young / John A Zapp 
  

	 	Re:	 Development of Arbor Trails Chuy’s 

 Gentlemen: 
 This letter agreement (this
“Agreement”) sets forth our mutual understanding with respect to the proposed development of the Arbor Trails Chuy’s (as defined herein) and is delivered pursuant to the terms of that certain Asset Purchase Agreement dated as
of the date hereof (the “Purchase Agreement”), by and among the undersigned (the “Company”), Three Star Management, Ltd. (“Developer”) and the other parties thereto. Capitalized terms used but not
defined in this Agreement have the meanings assigned to them in the Purchase Agreement. 
 MY/ZP IP Group, Ltd.,
a Texas limited partnership formerly known as Chuy’s-Comida Deluxe, Inc. and affiliated with Developer (“IP Group”), will assign to an affiliated Texas limited partnership to be formed (the “Landlord Entity”)
that certain Contract for Sale (the “Land Contract”) between IP Group and CP Austin Forum 71, L.P., a Texas limited partnership (“CP Austin”) for the purchase of Lot 4, Block A, Arbor Trails Subdivision, a
subdivision in the City of Austin, Travis County, Texas, according to the map or plat recorded as Document Number 200500129, in the Official Public Records of Travis County (the “Land”). The Land Contract obligates CP Austin to
process applications for, and use diligent efforts to obtain, the approval of all applicable governmental authorities and/or private entities so as to authorize the construction of a Chuy’s restaurant on the Land (the “Arbor Trails
Chuy’s”). The Land is encumbered by various restrictions that regulate exterior colors, materials, signs, height and other matters pertaining to the improvements that may be built upon the Land (the “Site
Restrictions”). 
 Subject to (a) CP Austin’s satisfaction of all conditions precedent under,
and performance of its obligations under, the Land Contract, and (b) the Landlord Entity’s receipt of all necessary approvals to build the Arbor Trails Chuy’s, each of which approvals shall be in a form satisfactory to Developer, in
its sole discretion (including without limitation building permits, sign permits, site development permits, curb cut 

 Three Star Management, Ltd. 
 November 7, 2006 
  Page
 2
 
  

 
approvals, construction plan approvals and architectural approvals from all applicable governmental authorities and/or private persons or entities) and of construction bids for the construction
of and installation of all fixtures, furniture and equipment in, the Arbor Trails Chuy’s, all in amounts acceptable to Developer, in its sole discretion (collectively, the “Acquisition Conditions”), and with the caveat that the
Site Restrictions may require modification of the exterior of the Arbor Trails Chuy’s from the look of other “ground up” constructed units owned by the Seller Group and in operation as of the date hereof (the “Other
Units”), Developer will take all action reasonably necessary or proper to cause the Landlord Entity to deliver the Arbor Trails Chuy’s to the Company as a “turn-key” operation with the look, quality and fixtures of the
completed Arbor Trails Chuy’s substantially similar to the look, quality and fixtures of the Other Units, except as may be required by the Site Restrictions, all as more particularly set forth in the Lease (defined below). Developer will have
the right to terminate this Agreement by notice to the Company if the Acquisition Conditions are not satisfied in Developer’s sole discretion; provided, however, that if the unsatisfied Acquisition Condition(s) are unacceptable based solely on
increases in the anticipated cost of delivering the Arbor Trails Chuy’s in the condition required by this Agreement, and if the Company agrees to pay the excess cost in a manner reasonably satisfactory to Developer, upon mutual execution of
agreements that require the Company to pay such excess cost, this Agreement will continue in force and effect. The package of furniture, fixtures and equipment to be delivered pursuant to this paragraph (the “FF&E”) shall be as
set forth on Annex A attached hereto. 
 The parties expect the Arbor Trails Chuy’s to be completed
on or about the third quarter of 2007, but the Company acknowledges that this is an estimate and agrees that there will be no penalty to Developer or the Landlord Entity if completion of the Arbor Trails Chuy’s is delayed or accelerated.
Developer or the Landlord Entity will bear all costs associated with the initial construction of the Arbor Trails Chuy’s and the installation of the FF&E therein. These costs will include sales taxes, ad valorem taxes during the period of
construction, permitting fees, development fees, and the costs of labor, materials and acquisition and installation of the FF&E. As among Developer, Landlord Entity and the Company, prior to the Delivery Date (defined below) the Landlord Entity
will be responsible for all liability related to or arising out of the development, construction and physical condition of the Arbor Trails Chuy’s. The Landlord Entity will assign to the Company all construction and FF&E warranties upon the
Delivery Date and thereafter the Company will be responsible for all costs of maintenance, repair, ownership and/or occupancy of the Arbor Trails Chuy’s. The Company also will be responsible for procuring all food and beverage items, all costs
relating to the hiring and training of personnel or advertising related to the opening of the location, and all other costs of operating the restaurant and for all costs set forth in the Lease. 

On the Delivery Date, the Landlord Entity and the Company will enter into a lease of the Land (the
“Lease”) in substantially the form attached hereto as Annex B. Upon substantial completion of the Arbor Trails Chuy’s, the Landlord Entity will deliver to the 

 Three Star Management, Ltd. 
 November 7, 2006 
  Page
 3
 
  

 Company a written notice advising the Company that the Arbor Trails Chuy’s is
substantially complete (the “Inspection Notice”) and that a certificate of occupancy has been issued by the applicable governmental authorities. The Company will have 15 Business Days from its receipt of the Inspection Notice to
inspect the Arbor Trails Chuy’s and to request correction of any defects in materials or workmanship (“Defects”). Following correction of any Defects, the Landlord Entity will deliver to the Company a written notice of
completion of the Arbor Trails Chuy’s and of tender of delivery of the Arbor Trails Chuy’s (the “Completion Notice”), together with two (2) counterparts of the Lease, executed by the Landlord Entity. Within 5 Business
Days following receipt of the Completion Notice, the Company will deliver to the Landlord Entity an executed counterpart to the Completion Notice (the “Acknowledgement”) and one fully executed counterpart to the Lease. The Delivery
Date shall occur, and rent will begin to accrue under the Lease, on the earlier of (i) the date the Company opens the Arbor Trails Chuy’s for business or (ii) 5 Business Days after delivery by the Company of an executed counterpart of
the Completion Notice. 
 Not later than 15 Business Days following the first Business Day of the seventeenth
month of continuous operation of the Arbor Trails Chuy’s by the Company, the Company will, or will cause its independent accounting firm to, prepare and deliver to the Developer a statement (the “Statement”) setting forth the
trailing 12-month store level EBITDAT for the Arbor Trails Chuy’s (the “Profit Calculation”). The Profit Calculation will be prepared in a manner consistent with those accounting practices used to evaluate EBITDA for
Chuy’s of Shenandoah, Ltd in the financial statement and projections attached hereto as Annex C. If the Developer has any objections to the Profit Calculation, it will deliver a detailed statement (the “Statement of
Objections”) describing its objections to the Company within 30 calendar days of its receipt of the Statement. If the Developer fails to notify the Company of any such dispute within such 30-calendar day period, the Statement delivered to
it will be deemed to be the “Final Statement.” The Developer and the Company will use commercially reasonable efforts to resolve any such objections, and each party will (i) provide the other party and its Representatives with
full access during normal business hours to the books and records related to the Profit Calculation and (ii) fully cooperate with all reasonable requests by the other party in connection with such party’s review of the Profit Calculation,
the Statement and the Statement of Objections. 
 If a final resolution with respect to the Profit Calculation
is not obtained within 30 calendar days after the Company has received the Statement of Objections, the Developer and the Company will mutually appoint a nationally recognized accounting firm independent of the Landlord Entity, Developer and the
Company (the “Accounting Referee”) to review the final Profit Calculation proposed by each party (each, a “Final Offer”). If the parties fail to select the Accounting Referee within 10 Business Days after the
expiration of the 30-calendar day negotiation period, either the Landlord Entity, on behalf of itself and Developer, or the Company may request JAMS to appoint an independent firm of certified public accountants to perform the services required by
the Accounting Referee. 

 Three Star Management, Ltd. 
 November 7, 2006 
  Page
 4
 
  

 Each party will cooperate with the Accounting Referee and provide the
Accounting Referee with information reasonably requested by it and necessary to assess the final offers. The decision of the Accounting Referee as to which Final Offer is equal to or closest to the actual trailing 12-month store level profit of the
Arbor Trail’s Chuy’s as determined by the Accounting Referee will be final and binding on all parties (the “Final Determination”). The fees and expenses of the Accounting Referee and the fees of JAMS, as applicable, will
be paid by the party whose Final Offer is the furthest from the Final Determination. 
 Once the Profit
Calculation has been finalized in accordance with the terms herein, the Company will pay to you by wire transfer of immediately available funds to a bank account designated by you an amount (the “Purchase Price”) equal to the Profit
Calculation multiplied by four (4). From and after the date the Company takes possession of the Arbor Trails Chuy’s, except for its obligations to pay the Purchase Price, the Company will have all right, title and interest to the profits of the
Arbor Trails Chuy’s and will be responsible for any losses resulting from the operation of the Arbor Trails Chuy’s. Title to the FF&E will transfer to the Company upon payment of the Purchase Price pursuant to an “as is” bill
of sale. 
 Each of the Developer and the Landlord Entity will use, and cause its Affiliates to use,
commercially reasonable efforts in the performance of their obligations hereunder and under the Lease, as applicable. The quality of the development services provided by Developer hereunder will be substantially equivalent to the quality of
development services historically provided by you with respect to the development of the Other Units (the Company acknowledging that the obligation to obtain approvals for the development is the obligation of CP Austin and not within
Developer’s control). 
 To the maximum extent permitted by Law, Developer will indemnify, hold harmless,
protect and defend (with counsel acceptable to the Company) the Company and its officers, directors, employees, agents and contractors, from and against any and all claims, demands, actions, fines, penalties, liabilities, losses, damages, injuries
and expenses (including, without limitation, actual attorneys’, consultants’ and expert witnesses’ fees and costs at the pre-trial, trial and appellate levels, on a full indemnity basis) in any manner related to, arising out of or in
connection with: (a) the willful misconduct or gross negligence by the Developer, the Landlord Entity, or the agents or employees or either Developer or the Landlord Entity in the performance of Developer’s obligations under this
Agreement; and (b) any failure to perform Developer’s obligations under this Agreement to the extent such failure was within Developer’s control, and subject in all events to the Acquisition Conditions. 

To the maximum extent permitted by Law, the Company will indemnify, hold harmless, protect and defend (with counsel
acceptable to Developer) Developer and its officers, directors, employees, agents and contractors, from and against any and all claims, demands, actions, fines, penalties, liabilities, losses, damages, injuries and

 Three Star Management, Ltd. 
 November 7, 2006 
  Page
 5
 
  

 
expenses (including, without limitation, actual attorneys’, consultants’ and expert witnesses’ fees and costs at the pre-trial, trial and appellate levels, on a full indemnity
basis) in any manner related to, arising out of or in connection with any failure to perform the Company’s obligations under this Agreement to the extent such failure was within the Company’s control, and subject in all events to the
Acquisition Conditions. 
 The provisions set forth in Article VIII of the Purchase Agreement are incorporated
herein by reference and apply to this Agreement mutatis mutandis. 
 [Remainder of page intentionally left blank]

 If this accurately reflects your understanding, please execute two copies of
this Agreement. 
  

			
	 Very truly yours

	
	CHUY’S OPCO, INC.
		
	 By:
	 	 /s/ David J. Oddi

		 	 Name: David J. Oddi

		 	 Title Vice President

 

			
	 ACKNOWLEDGED AND AGREED TO:

	
	THREE STAR MANAGEMENT, LTD.
	
	 By: Three Star Management GP, LLC,
 Its General Partner

		
	 By:
	 	 /s/ Michael R. Young

		 	 Name: Michael R. Young

		 	 Title: President

	
	MY/ZP IP GROUP, LTD.
	
	 By: MY/ZP IP Group GP, LLC,
 Its General Partner

		
	 By:
	 	 /s/ Michael R. Young

		 	 Name: Michael R. Young

		 	 Title: President

  
 Signature
Page Arbor Trails Letter AgreementRecipe License Agreement

 Exhibit 10.10 
 RECIPE LICENSE AGREEMENT 
 This Recipe License Agreement
(“Agreement”) is entered into effective as of November 7, 2006 (the “Effective Date”) by and between Chuy’s Opco, Inc., a Delaware corporation (“Licensor”), and MY/ZP IP Group, Ltd., a
Texas limited partnership (“Licensee”). 
 RECITALS: 

A. Licensor is a party to that certain Asset Purchase Agreement (the “Purchase Agreement”), dated as of
the date hereof, by and among Licensor, MY/ZP on Hwy 183, Inc., MY/ZP of S.A. – 281, Ltd., MY/ZP of Round Rock, Ltd., MY/ZP of Shenandoah, Ltd., MY/ZP Central Texas, Ltd., MY/ZP North Lamar, Ltd., MY/ZP on McKinney, Inc., MY/ZP of River Oaks,
Inc., MY/ZP IP Group, Ltd., Three Star Management, Ltd., Michael Young and John Zapp. 
 B. In connection with
the Purchase Agreement, Licensor acquired rights in all recipes and lists of ingredients used in or held for use in the Business (as defined in the Purchase Agreement) (collectively, the “Licensor Recipes”); 

C. Licensee desires to obtain, and Licensor desires to grant to Licensee, a license to allow the use of certain of the
Licensor Recipes, by Licensee solely for the benefit of Chuy’s Boat Towne, Ltd., Shady Grove, Inc., and Lake Austin, Ltd. (collectively, the “Non-Chuy’s Restaurant Group”), relating to the respective restaurant businesses
conducted by the members of the Non-Chuy’s Restaurant Group under the names “Hula Hut,” “Shady Grove” and “Lucy’s Boatyard,” respectively, exclusively at the locations identified on Exhibit A (attached
hereto and incorporated herein by this reference) (the “Locations”), on the terms and conditions of this Agreement. 
 D. All capitalized terms used but not defined herein will have the respective meanings set forth in the Purchase Agreement. 
 1. License Grant. 
 (a) License. Subject to the
terms and conditions of this Agreement, Licensor hereby grants to Licensee a limited, non-exclusive, royalty-free, irrevocable, and perpetual right and license to (i) use, reproduce, modify, improve and create derivative works of the Licensor
Recipes historically used by the Licensee and/or the Non-Chuy’s Restaurant Group at or from the Locations up to and including the Closing Date (collectively, the “Licensed Recipes”), and (ii) to make, have made, use, sell
and offer for sale any food or beverage items developed by Licensee and/or the Non-Chuy’s Restaurant Group pursuant to a sublicense practicing the Licensed Recipes at or from the Locations (collectively, the “Permitted Use”).
This Agreement does not permit use of the Licensed Recipes for mass-marketed, pre-packaged foods and beverages intended as a separate line of business. Licensee may make a reasonable number of copies of the Licensed Recipes consistent with the
Permitted Use. Any and all rights and licenses with respect to the Licensed Recipes not expressly granted to Licensee under this Agreement are reserved by Licensor. 

 (b) Limited Right to Transfer and/or Sublicense. Except as otherwise
expressly provided in this Section 1(b), Licensee may not transfer, assign or sublicense, in whole or in part, the right and license granted to Licensee pursuant to Section 1(a) with respect to the Licensed Recipes without the prior
written consent of Licensor; provided, however, that Licensee may, at any time and from time to time, (i) sublicense its right and license to use the License Recipes for the Permitted Use to any member of the Non-Chuy’s
Restaurant Group exclusively for use at the Locations, (ii) assign its rights and obligations, in whole, under this Agreement to (1) any member of the Non-Chuy’s Restaurant Group exclusively for use at the Locations or (2) upon
at least ten (10) days’ prior written notice to Licensor, any acquiror of all or substantially all of Licensee’s assets (whether by way of merger, asset sale or otherwise) exclusively for use at the Locations, in each case, to the
extent that such Person agrees in writing to be bound by and subject to the terms and conditions of this Agreement. As a condition to any sublicense permitted pursuant to clause (i) above, Licensee will require the sublicensee to comply with
the provisions of this Agreement (including the Permitted Use) and Licensee will be responsible for any violation or breach of this Agreement due to the acts or omissions of such sublicensee and the failure to enter into a sublicense with any Person
or entity. In addition, Licensee will include a provision in each sublicense agreement that Licensor is an intended third party beneficiary of such agreement and will have the right to enforce directly all rights of or restrictions imposed by
Licensee on the sublicensee with respect to the Licensed Recipes under such agreement. Any attempted or actual transfer, assignment or sublicense in violation of the provisions of this Section 1(b) will be void and Licensee will be liable to
Licensor for any damages resulting from such attempted transfer, assignment or sublicense. For the avoidance of doubt, any unintentional breach by Licensee of its obligations under Section 3 (Confidentiality) will not be deemed a transfer,
assignment or sublicense of the Licensed Recipes but will be subject to other rights and remedies available to Licensor under this Agreement. 
 (c) Royalty-Free License. The rights and licenses granted to Licensee pursuant to this Section 1 are royalty-free and fully paid up. Licensor acknowledges and agrees that Licensee has provided
adequate consideration to Licensor for Licensor to enter into and perform under this Agreement. 
 (d)
Equitable Remedies. Licensee acknowledges and agrees that in the event of any breach of the provisions of this Section, Licensor would suffer irreparable injury for which monetary damages would be an inadequate remedy, and, without limitation
of any other rights or remedies available to Licensor, Licensor will be entitled to equitable relief, including injunctive relief, for such breach in any court of competent jurisdiction. 

2. No Ownership. Licensee acknowledges and agrees that (a) Licensee is only granted a license to use the Licensed Recipes on
the terms and conditions of this Agreement and (b) Licensee will not acquire any ownership in the Licensed Recipes by virtue of this Agreement. Licensor acknowledges and agrees that Licensor will not acquire any rights in any modification,
improvement or other derivative work to the Licensed Recipes created by Licensee and/or any sublicensee. 

  
 2 

 3. Confidentiality. Licensee will maintain, and will cause each member of the
Non-Chuy’s Restaurant Group and each sublicensee to maintain, the confidentiality of the Licensed Recipes in the same manner in which Licensee treats its own recipes and lists of ingredients. In no event will Licensee make any unauthorized
public disclosure of the Licensed Recipes (including any posting of the Licensed Recipes or a detailed list of ingredients of the Licensed Recipes on the Internet); provided, that reasonable disclosure of a list of ingredients in menus and other
promotional materials to the extent consistent with past practice or required by law are permissible. 
 4. DISCLAIMERS;
LIMITATIONS ON LIABILITY. 
 (a) THE LICENSED RECIPES ARE PROVIDED ON AN “AS IS” BASIS, WITH ALL
FAULTS. LICENSOR DOES NOT MAKE, AND EXPRESSLY DISCLAIMS, ANY AND ALL WARRANTIES, WHETHER EXPRESS, IMPLIED OR OTHERWISE, WITH RESPECT TO THE LICENSED RECIPES INCLUDING ANY IMPLIED WARRANTIES OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE, OR
ANY WARRANTIES OF TITLE OR NON-INFRINGEMENT, OR ANY WARRANTIES THAT MAY ARISE FROM USAGE OF TRADE OR COURSE OF DEALING. LICENSOR EXPRESSLY DISCLAIMS ANY WARRANTIES NOT EXPRESSLY STATED HEREIN. 

(b) IN NO EVENT WILL LICENSOR BE LIABLE FOR ANY INDIRECT, CONSEQUENTIAL, INCIDENTAL, SPECIAL OR PUNITIVE DAMAGES
(INCLUDING INTERRUPTION OF SERVICE, LOSS OF DATA, LOSS OF REVENUE OR PROFIT, OR LOSS OF TIME OR BUSINESS) ARISING OUT OF OR RELATING TO THIS AGREEMENT OR THE LICENSED RECIPES, WHETHER LIABILITY IS ASSERTED IN CONTRACT OR IN TORT (INCLUDING STRICT
LIABILITY, PRODUCTS LIABILITY OR NEGLIGENCE) OR OTHERWISE AND REGARDLESS OF WHETHER LICENSOR HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES. 
 (c) LICENSEE AGREES THAT LICENSOR’S TOTAL LIABILITY FOR DAMAGES FOR ANY CAUSE(S) WHATSOEVER ARISING OUT OF OR RELATING TO THIS AGREEMENT OR THE LICENSED RECIPES, AND REGARDLESS OF THE FORM OF ACTION,
WHETHER IN CONTRACT OR IN TORT (INCLUDING STRICT LIABILITY, PRODUCTS LIABILITY OR NEGLIGENCE) OR OTHERWISE, SHALL BE LIMITED TO THE TOTAL AMOUNT OF TEN DOLLARS (US$10.00). 
 5. Default; Termination. In the event of any default under this Agreement which remains uncured thirty (30) days following receipt of written notice of such default, the non-defaulting party
may terminate this Agreement upon delivery of written notice to the defaulting party. In the event this Agreement is terminated pursuant to this Section 5, Licensee will return, and will cause each sublicensee to return, (or certify the
destruction of) all written copies of the Licensed Recipes and will cease further use, and will cause each sublicensee to cease further use, of the Licensed Recipes. 
 6. Assignability. Except as otherwise expressly provided in Section 1(b), Licensee may not assign or transfer any of its rights or obligations under this Agreement (whether

  
 3 

 
by way of merger, asset sale or otherwise) without the prior written consent of Licensor. Any attempted or actual assignment or transfer in violation of the provisions of this Section 6 will
be void. 
 7. Waiver of Compliance. Except as otherwise provided in this Agreement, the failure by any party to comply
with any obligation, covenant, agreement or condition under this Agreement may be waived by the party entitled to the benefit thereof only by a written instrument signed by the party granting such waiver, but such waiver or failure to insist upon
strict compliance with such obligation, covenant, agreement or condition will not operate as a waiver of, or estoppel with respect to, any subsequent or other failure. The failure of any party to enforce at any time any of the provisions of this
Agreement will in no way be construed to be a waiver of any such provision, or in any way to affect the validity of this Agreement or any part hereof or the right of any party hereafter to enforce each and every such provision. No waiver of any
breach of such provisions will be held to be a waiver of any other or subsequent breach. 
 8. Notices. All notices and
other communications required or permitted hereunder will be in writing and, unless otherwise provided in this Agreement, will be deemed to have been duly given when delivered in person or when dispatched by telegram or electronic facsimile transfer
(confirmed in writing by mail simultaneously dispatched) or one Business Day after having been dispatched by a nationally recognized overnight courier service to the appropriate party at the address specified below: 

If to the Licensor, to: 
 Chuy’s Opco, Inc. 
 1623 Toomey Road 

Austin, Texas 78704 
 Facsimile No.: 512-476-5157 
 Attention: Chief Executive Officer

 with copies to: 
 Goode Partners LLC 
 667 Madison Avenue 

21st Floor 
 New York, New York 10021 
 Facsimile: 212-317-2827 

Attention: David J. Oddi 
 and 
 Jones Day 

222 East 41st Street 
 New York, New York 10017 
 Facsimile No.: 212-755-7306 

Attention: Robert A. Profusek, Esq. 

  
 4 

 If to the Licensee, to: 

MY/ZP IP Group, Ltd. 
 1623 Toomey Road 
 Austin, Texas 78704 

Facsimile No.: 512-476-5157 
 Attention: Mike Young/John Zapp 
 with a copy to: 

Graves, Dougherty, Hearon & Moody, P.C. 

401 Congress Avenue, Suite 2200 
 Austin, Texas 78701 
 Facsimile No.: 512-478-1976 

Attention: Clarke Heidrick, Esq. 
 or to such other address or addresses as any such party may from time to time designate as to itself by like notice. 
 9. Severability. The illegality or partial illegality of any or all of this Agreement, or any provision hereof, will not affect the validity of the remainder of this Agreement, or any provision
hereof, and the illegality or partial illegality of this Agreement will not affect the validity of this Agreement in any jurisdiction in which such determination of illegality or partial illegality has not been made, except in either case to the
extent such illegality or partial illegality causes this Agreement to no longer contain all of the material provisions reasonably expected by the parties to be contained herein. 

10. Governing Law. This Agreement will be construed and enforced in accordance with and governed by the laws of the State of
Texas, without giving effect to the principles of conflict of laws thereof. 
 11. Dispute Escalation and Binding
Arbitration; Jurisdiction. 
 (a) In the event of any dispute, controversy or claim of any kind or nature
arising under or in connection with this Agreement (including disputes as to the creation, validity, interpretation, breach or termination of this Agreement) (a “Dispute”), then upon the written request of either party, each of
Licensor and Licensee will appoint a designated senior business executive whose task it will be to meet for the purpose of endeavoring to resolve the Dispute. The designated executives will meet as often as the parties reasonably deem necessary in
order to gather and furnish to the other all information with respect to the matter in issue which the parties believe to be appropriate and germane in connection with its resolution. Such executives will discuss the Dispute and will negotiate in
good faith in an effort to resolve the Dispute without the necessity of any formal proceeding relating thereto. The specific format for such discussions will be left to the discretion of the designated executives but may include the preparation of
agreed upon statements of fact or written statements of position furnished to the other party. No formal proceedings for the resolution of the Dispute 

  
 5 

 
may be commenced until the earlier to occur of (i) a good faith mutual conclusion by the designated executives that amicable resolution through continued negotiation of the matter in issue
does not appear likely or (ii) the 30th day after the initial request to negotiate the Dispute. 
 (b) Any
Dispute, if not resolved informally through negotiation between the parties as contemplated by Section 11(a), will be resolved by final and binding arbitration conducted in accordance with and subject to JAMS Comprehensive Arbitration Rules and
Procedures of JAMS then in effect. One arbitrator will be selected by the parties’ mutual agreement or, failing that, by JAMS (provided, that, in any event, the arbitrator must be listed as an approved arbitrator by the Dallas office of JAMS
and be a former Texas state civil court judge or federal court judge) (the “Arbitrator”), and the Arbitrator will allow such discovery as is appropriate, consistent with the purposes of arbitration in accomplishing fair, speedy and
cost effective resolution of disputes. The Arbitrator will reference the Federal Rules of Civil Procedure then in effect in setting the scope of discovery, except that no requests for admissions will be permitted and interrogatories will be limited
to identifying (i) persons with knowledge of relevant facts and (ii) expert witnesses and their opinions and the bases therefore. Judgment upon the award rendered in any such arbitration may be entered in any court having jurisdiction
thereof. Any negotiation, mediation or arbitration conducted pursuant to this Section 11 will take place in Austin, Texas. Each party will bear its own costs and expenses with respect to any such negotiation or arbitration, including one-half
of the fees and expenses of the arbitrators, if applicable. Other than those matters involving injunctive relief or any action necessary to enforce the award of the arbitrators, the parties agree that the provisions of this Section 11 are a
complete defense to any suit, action or other proceeding instituted in any court or before any administrative tribunal with respect to any Dispute. Nothing in this Section 11 prevents the Parties from exercising their right to terminate this
Agreement in accordance with Section 5 or prevents or delays Licensor from exercising its rights under Section 1(d). 
 (c) EACH OF THE PARTIES HERETO HEREBY IRREVOCABLY WAIVES ANY AND ALL RIGHT TO TRIAL BY JURY IN ANY LEGAL PROCEEDING ARISING OUT OF OR RELATED TO THIS AGREEMENT OR THE TRANSACTIONS CONTEMPLATED HEREBY.

 12. Counterparts. This Agreement may be executed in two or more separate counterparts, each of which, when so
executed, will be deemed to be an original. Such counterparts will together constitute one and the same instrument. This Agreement may be executed by facsimile signatures. 
 13. Entire Agreement; Amendment; Interpretation. This Agreement (including the Exhibits attached hereto) constitutes the entire agreement and supersede all prior agreements and understandings, both
written and oral, among the parties with respect to the subject matter of this Agreement. This Agreement may only be modified or amended upon the mutual written consent of the parties. Unless the context otherwise requires, (i) all references
to Sections are to be Sections of or to this Agreement, (ii) each term defined in this Agreement has the meaning assigned to it, (iii) words in the 

  
 6 

 
singular include the plural and vice versa, (iv) the term “including” means “including without limitation,” (v) all reference to $ or dollar amounts will be
to lawful currency of the United States, (vi) to the extent the term “day” or “days” is used, it will mean calendar days and (vii) the pronoun “his” refers to the masculine, feminine and neuter. 

[Remainder of page intentionally left blank] 

  
 7 

 IN WITNESS WHEREOF, each of the signatories hereto has caused this Agreement
to be signed by its duly authorized officer as of the date first above written. 
  

			
	CHUY’S OPCO, INC.
		
	 By:
	 	 /s/ David J. Oddi

		 	 Name: David J. Oddi

		 	 Title: Vice President

  

			
	MY/ZP IP GROUP, LTD.
		
	 By:
	 	 MY/ZP IP GROUP, LLC,
 its sole general partner

		
	 By:
	 	 /s/ Michael R. Young

		 	 Name: Michael R. Young

		 	 Title: President

 Attachment: 
 Exhibit A – Locations 

  
 Signature
Page to 
 Recipe License Agreement

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00192-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00192-of-00352.parquet"}]]