Document:

Master Loan Agreement

  Exhibit 10.10
 MASTER LOAN
AGREEMENT
 This Master Loan Agreement (this “Agreement”) is made to be effective as of December 31, 2002, by and among the following
parties:
 (i)        Toyota Motor Credit Corporation, a
Delaware corporation (“TMCC”),
 (ii)      Sonic Automotive,
Inc., an Delaware corporation (“Sonic”),
 (iii)     The entities
identified in Schedule 1 attached hereto (collectively the “Borrower”).
 RECITALS
 A.       Borrower is or will be the owner of various parcels of real estate located in various
cities and states which either have improvements, or upon which Borrower will construct improvements, useful for the retail sales of automobiles.
 B.        Borrower will lease such parcels and the improvements to related entities who will operate retail automotive dealerships thereon. Borrower and such
lessees are wholly owned, directly or indirectly, by Sonic.
 C.        Borrower
has requested TMCC to make loans to Borrower for the purpose of (i) purchasing properties upon which Borrower will construct automobile dealership facilities, (ii) constructing such improvements, and (iii) providing permanent financing of such
purchases and improvements. Borrower and Sonic reasonably may be expected to benefit, directly or indirectly, by such loans from TMCC.
 NOW, THEREFORE, in
consideration of the premises and the mutual agreements set forth below, the parties agree as follows:
 ARTICLE 1.
 General Definitions
 Section 1.1    Definitions.  In addition to other defined terms herein, as used in this Agreement and unless the context otherwise requires, the following terms shall have the
respective meanings set forth below. Articles 4 and 5 contain additional definitions applicable to the Construction Loan and Permanent Loan
respectively.
 (a)       Acquisition Advance.  Any advance of loan proceeds under either the Construction Loan or Permanent Loan by TMCC to Borrower or on behalf of Borrower to finance the costs of the purchase of a Property or refinance existing indebtedness secured by a
Property pursuant to Article 3.
 
 

   (b)     Advance.  Any advance of
the proceeds of the Loans by TMCC to Borrower or on behalf of Borrower. An Advance shall include: (i) an Acquisition Advance pursuant to Article 3, (ii) a Draw pursuant to Article
4, or (iii) a Permanent Loan pursuant to Article 5.
 (c)       Applicable Law.  All laws, rules and regulations applicable to the Person, Property, conduct, transaction, covenant or Loan Document in
question, including all (i) applicable common law and equitable principles, (ii) provisions of all applicable city, county, state and federal constitutions, statutes, ordinances, rules, regulations and orders of a Governmental Authority (including,
without limitation, all pollution control, environmental protection, zoning and land use regulations, building codes and all restrictions and requirements imposed by cities where the Property is located), and (iii) orders, judgments and decrees of
all courts and arbitrators. Applicable Law shall not, however, include the Environmental Laws (defined below).
 (d)       Appraisal.   An MAI appraisal reflecting the value of a particular Property.
The Appraisal must meet all the standards and requirements of TMCC, and be prepared by an appraiser acceptable to TMCC.
 (e)       Appraised Value is the value of a Property reflected in an Appraisal.
 (f)       Best Knowledge.   Facts that are within the actual knowledge of any officer of Borrower or Guarantor (as applicable)
after due inquiry of employees of Borrower or Guarantor reasonably likely to possess information of the nature described.
 (g)       Borrower.    The entities listed in Schedule 1. When applicable, the term shall be deemed as
reference to all such Borrowers collectively, or to an individual Borrower. All the entities listed in Schedule 1 shall be co-makers of the Construction Promissory Note and the Permanent Promissory
Note, and therefore all such entities are Borrowers. However, an individual Borrower shall be the record title owner of each Property.
 (h)       Borrowing Notice.    A written notice of Borrower’s request for an Acquisition Advance, in the form attached hereto as Exhibit 3.2.
 (i)        Business Day.
   Any day excluding Saturday, Sunday and any day which is a legal holiday under the laws of the State of California or is a day on which banking institutions located in such state is closed. Unless the terms herein specifically provide
that a period of time is measured by Business Days, time periods shall be deemed to refer to calendar days.
 (j)        Collateral.    All of the Properties, and all other real or personal property and interests in same that now or
hereafter secure the payment and performance of the Obligations.
 (k)       Construction Loan.    The construction revolving line of credit in the maximum principal amount of $50,000,000.00 extended to Borrower from TMCC pursuant to Article 4 as evidenced by that certain Construction Loan Promissory Note dated as of even date herewith in the principal amount of $50,000,000.00, including any and all amendments, modifications, renewals, increases and extensions thereof and any
advances thereunder.
 
 

  (l)        Cost of Acquisition.    For a Property that is purchased by Borrower under an Acquisition Advance, the purchase price of the Property as reflected in the Purchase Contract, together with such other expenses incurred in connection with the acquisition
of such Property, approved by TMCC, including, but not limited to title fees, title insurance premiums, legal expenses, survey expenses, recording fees, escrow fees, environmental report expenses, organizational expenses, documentation stamps and
taxes and broker’s commissions.
 (m)     Deed of Trust.
  Collectively, or any one or each, of the deeds of trust, mortgages or other instruments now or hereafter granting or evidencing liens on the Properties (whether called a “Deed of Trust”, “Mortgage” or other term),
executed by one or more Borrowers, as grantor, or mortgagor, as the case may be, to the trustees named therein, if applicable, in trust for TMCC as beneficiary, or to TMCC as mortgagee, as the case may be, which will constitute a first priority lien
on a Property, subject only to the Permitted Encumbrances.
 (n)       Default or Event of Default.   As defined in Article 12, or in any of the other Loan Documents.
 (o)       Effective Date.   The date of this Agreement as
set forth above.
 (p)       Environmental Laws.
  All federal, state and local laws, rules, regulations, ordinances, programs, permits, guidances, and orders relating to health, safety or environmental matters. This term shall include (i) the Comprehensive Environmental Response,
Compensation and Liability Act of 1980; Federal Water Pollution Control Act (33 U.S.C. Section 1317), (ii) the Federal Resource Conservation and Recovery Act (42 U.S.C. Section 6901, et seq.), (iii) the Federal Comprehensive Environmental
Response, Compensation and Liability Act (42 U.S.C. Section 9601, et seq.), and (iv) the Toxic Substances Control Act (15 U.S.C., Section 2601 et seq.). It shall also include any rules or regulations adopted by any administrative agency,
including but not limited to, the Environmental Protection Agency, the Occupational Safety and Health Administration, and any similar state or local agency having jurisdiction over any Property.
 (q)       Environmental Report.   A Phase 1 and/or Phase 2 environmental site
assessment of a Property, conforming to the “Standard Practice for Environmental Site Assessments: Phase I Environmental Site Assessments Process” of the American Society for Testing and Materials (the “Standard Practice”). The
consultant’s report must follow the format recommended under the Standard Practice. 
 (r)       Force Majeure.   An event that prevents Borrower from the performance of any act required hereunder by reason of acts of God, the elements,
governmental regulations or restrictions, unavailability of necessary materials, supplies, or labor, strikes, interruptions of public transportation services or facilities, or other cause beyond its reasonable control.
 (s)       GAAP.   Generally accepted accounting principles in the
United States of America in effect from time to time.
 (t)        Governmental Authority.   Any state, commonwealth, federal, foreign, territorial, or other court or governmental department, commission, board, bureau, agency, or instrumentality.
 
 

  (u)       Guarantor or
Guarantors.   Sonic, and its respective successors and assigns, as applicable, or any other person or entity who may hereafter guarantee payment or performance of the whole or any part of the
Obligations.
 (v)       Guaranty Agreement or
Guaranty Agreements.   The instrument or instruments executed by a Guarantor.
 (w)     Hazardous Material.   Any radioactive, hazardous, or toxic substance, material, waste, chemical, or similar item, the presence of which on any Property, or
the discharge, emission, release, or threat of release of which on or from the Property, is prohibited or otherwise regulated by any Environmental Laws.
 (x)       Improvements.   Any and all buildings and other improvements which are either existing on Property owned or to be
purchased by Borrower, or to be constructed by Borrower on the Property as contemplated herein.
 (y)       Insurance Policies.   The insurance coverage required by the applicable Deed of Trust or other Loan Document pertaining to a Property. An
Insurance Policy shall refer to any one of the Insurance Policies.
 (z)       Lessee.   Each lessee of a Property.
 (aa)     LIBOR.   The London Interbank Offered Rate for one (1) month deposits, as published by the Wall Street
Journal in its “Money Rates” section. Should the method of establishing LIBOR, or the publication of the London Interbank Offered Rates for one (1) month deposits in the Wall Street
Journal cease or be abolished, then LIBOR shall be based on a comparable index selected by TMCC. For each Advance LIBOR is initially determined on the date of the applicable amount funded. LIBOR shall be adjusted, as
necessary, as of the first calendar day of each month, based on the LIBOR rate in effect as of the last Business Day of the preceding month.
 (bb)     Loan Closing Date.   The effective date of either (i) the Construction Loan for a particular Construction Project, or (ii) a Permanent Advance under the
Permanent Loan.
 (cc)     Loan Documents.   This
Agreement, the Construction Promissory Note, Permanent Promissory Note, Deeds of Trust, Guaranty Agreements, Security Agreements, Environmental Indemnity, and all other documents, instruments and agreements now existing or hereafter entered into by
Borrower, or any Guarantor, or any other person with TMCC in relation to the Loans. A “Loan Document” shall refer to any one of said instruments. To the extent applicable, the term shall also
include any assignment of rents and leases (if executed as a separate instrument), consents and agreements executed by an Architect, Engineer and General Contractor. 
 (dd)     Loans.   All loans and advances of any kind made by TMCC pursuant to this Agreement, being the Construction
Loan under Article 4 and the Permanent Loan under Article 5. A Loan shall refer to any one of such
Loans.
 
 

  (ee)     Material Adverse Effect.
  The effect of any event or condition which, alone or when taken together with other events or conditions occurring or existing concurrently therewith, (i) has a material adverse effect upon the business, operations, Collateral, condition
(financial or otherwise) or business prospects of Borrower or Guarantor; (ii) has a material adverse effect upon the condition or value of the whole or any material part of the Collateral, the liens of TMCC with respect to the Collateral or any
material part thereof or the priority of such Liens; or (iii) materially impairs the ability of Borrower or Guarantor to perform its obligations under this Agreement, any Guaranty Agreement or any of the other Loan Documents to which it is a party,
including repayment of the Obligations when due.
 (ff)      Obligations.   All indebtedness (including principal and interest, together with all other amounts, payments, premiums, advances and other indebtedness) of Borrower or Guarantor to TMCC, whether direct or
indirect, absolute or contingent, due or to become due, now existing or hereafter arising, pursuant to or in connection with this Agreement, whether as maker, guarantor, surety, endorser or otherwise, including without limitation the Construction
Loan under Article 4 and the Permanent Loan under Article 5.
 (gg)     Permanent
Loan.    The mortgage revolving loan line of credit from TMCC to Borrower in the maximum principal amount of up to $100,000,000.00 extended by TMCC to Borrower pursuant to Article
5, to be evidenced by the Permanent Promissory Note to be executed upon the initial funding of loans hereunder, including any amendments, modifications, renewals, increases and extensions thereof and any advances thereunder.
Permanent Loans may also refer to the Permanent Advances made under the Permanent Loan in respect to a Property or Properties.
 (hh)     Permitted Encumbrances.    The encumbrances described in respect of any Property, with particularity, in
Schedule B to the Title Policy issued in connection with the Loan made in respect of such Property.
 (ii)      Person.   An individual, partnership, corporation, limited liability company, joint stock company, land trust, business trust, or unincorporated
organization, or a Governmental Authority.
 (jj)      Property.    The real property, Improvements, fixtures and appurtenances already owned or to be purchased by Borrower, which shall be the subject of a Loan, and which shall be pledged as Collateral to secure such Loan. Properties shall refer to one or more pieces of Property.
 (kk)     Purchase Contract.   The contract or other agreement pursuant to which Borrower shall purchase a Property for which an Acquisition Advance is requested under this Agreement.
 (ll)      Purchase Price.   The purchase price paid by Borrower to
purchase the Property under a Purchase Contract.
 (mm)  Restrictions.
  As to each Property, all conditions, restrictions and reservations (whether or not of record) affecting the ownership or use of such Property.
 
 

  (nn)     Security Agreements.   All
lien instruments (other than the Deeds of Trust) now existing or hereafter given to secure payment of the Indebtedness and other Obligations. A Security Agreement shall mean any one of such
instruments.
 (oo)     Survey.    A current certified
survey of the applicable Property satisfying the requirements set forth on Exhibit 1.1(kk) attached hereto.
 (pp)     Termination Date.    December 31, 2007, the date upon which the obligations of TMCC to make any further Advances hereunder shall
cease.
 (qq)     Title Commitment.   A Commitment for
Title Insurance (or other appropriate designation under the applicable State) issued by the Title Company on the appropriate form obligating the Title Company to issue the Title Policy in respect to a Property in accordance with the terms
herein.
 (rr)      Title Company.    Chicago Title
Insurance Company or its agents.
 (ss)     Title Policy.
  An ALTA loan policy of title insurance issued by the Title Company, without standard exceptions, in form and substance satisfactory to TMCC, and which must have a liability in the amount of the applicable Loan, if available, insuring, as
of the effective date of such Title Policy, that the fee simple title to the Property is vested in the applicable Borrower and that the lien of such Deed of Trust is a valid first priority lien on such Property, and containing the following
endorsements to the extent available in the applicable jurisdiction: 
 (i)        Comprehensive Endorsement;
 (ii)      ALTA form 3.1 Zoning Endorsement;

(iii)     Truth in Lending and Usury Endorsements;
 (iv)     Tie-in Endorsements;
 (v)       Revolving Credit Endorsement;
 (vi)     Future Advance Endorsement;
 (vii)    Last Dollar Endorsement;
 (viii)   Aggregation Endorsement;
 (ix)     Tax Parcel Endorsement; and 
 (x)       Such additional
endorsements as may be reasonably required by TMCC based upon its review of the Commitment and Survey. 
 (tt)      TMCC. Toyota Motor Credit Corporation, or any successor or assign of Toyota Motor Credit Corporation.
 
 

  ARTICLE 2.
 Conditions
Precedent
 Notwithstanding any other terms of this Agreement, TMCC will not be required to make any Loans or any Advances unless the following conditions
have been met as to each Borrower and Guarantor. Unless noted below, all such conditions must be satisfied as of the Effective Date hereof.
 Section
2.1    Representations True.    The representations and warranties contained in this Agreement and in any
other Loan Document are true in all material respects; there is not then in existence any Event of Default hereunder or any event which upon the service of notice or passage of time would constitute an Event of Default hereunder. This condition must
also be met on the date of each Advance.
 Section 2.2    Opinion of Counsel.   TMCC will have received an opinion of counsel to Borrower and Guarantor in the form required by TMCC.
 Section 2.3    Good Standing and Certified Copies.    TMCC will have received (a) a current certificate with respect to each
Borrower and Guarantor, or confirmation by telecommunication, if such confirmation is available, from the jurisdiction of organization of each such entity and each foreign jurisdiction where such entity’s failure to be duly qualified or
licensed would have a Material Adverse Effect; (b) certified copies of the governing documents of each Borrower and Guarantor, to the extent applicable; (c) signature and incumbency certificates with respect to the officers executing this Agreement,
and the other Loan Documents; and (d) a certified copy of the company action taken by Borrower and Guarantor authorizing execution, delivery and performance of this Agreement and the other Loan Documents.
 Section 2.4    Guaranty Agreement.    TMCC will have
received the Guaranty Agreement executed and delivered by Guarantor.
 Section 2.5    Loan
Documents.    All of the Loan Documents relating to the applicable Loan will have been executed by Borrower and Guarantor, as applicable, or other applicable persons or
entities, and delivered to TMCC. This condition must also be met on the date of each Advance.
 Section 2.6    Due Diligence.    TMCC will, to its satisfaction, have completed and received all audits, inspections,
examinations and surveys deemed necessary in the sole, absolute discretion of TMCC with respect to the Collateral and the financial and business condition of Borrower and Guarantor.
 Section 2.7    UCC Filings and Searches.    TMCC will, prior to each Loan,
have received UCC and other record searches acceptable to TMCC. Financing statements will be filed with the appropriate jurisdiction for each Loan when such Loan is made.
 Section 2.8    Approval by TMCC.    All Properties for which an Advance is
requested, and the anticipated use of the Property by Borrower, must be satisfactory to TMCC in its discretion prior to the making of each Advance for that Loan. Without limiting the conditions
 
 

  for TMCC’s approval, the Property must meet with TMCC’s approval both in terms of location of the Property and the manufacture brand of automobiles
to be sold by Borrower at such location. Borrower acknowledges that TMCC may, in its discretion, decline to approve an Advance on a Property intended for the sale of automobiles other than the Toyota brand.
 Section 2.9    Conditions to Advances.   In addition to any other conditions set forth herein or in
any other Loan Document, TMCC shall have no obligation to make any Advance to Borrower unless or until each of the following conditions are satisfied as to each applicable Advance:
 (a)       There shall exist no Event of Default on the date of the Advance.
 (b)       No event has occurred which has had a Material Adverse Effect on Borrower, Guarantor or the Collateral.
 (c)       All Loan Documents required by TMCC to be recorded or filed, shall have been recorded, filed or
delivered to Title Company for recording or filing. 
 (d)       TMCC shall have
received counterpart originals of each Insurance Policy (or satisfactory certificates of insurance).
 (e)       TMCC shall have received the applicable Title Commitment, together with written assurance from the Title Company to TMCC, in form and substance satisfactory to TMCC, that the Title
Policy shall be issued and delivered to TMCC without cost to TMCC, in accordance with the Loan Documents. 
 Section 2.10  Automobile Franchises.    Advances shall only be made with respect to Properties upon which:
 (a)       A wholly owned subsidiary of Guarantor will operate an automobile dealership for retail sales.
 (b)       The entity operating the dealership on a Property holds a franchise, or is approved for a
franchise, for the sale of Toyota automobiles, or another brand pursuant to a franchise with other manufactures or distributors approved by TMCC, on such Property.
 ARTICLE 3.
 Acquisition Advances
 Section
3.1    Acquisition Advances.    Subject to the conditions and limitations set forth herein, TMCC shall
make Acquisition Advances for (i) the purchase of a Property, or (ii) the refinance of existing indebtedness on a Property.
 Section 3.2    Allocation of Acquisition Advances.   Each Acquisition Advance shall be funded either under the Construction Loan (for Property upon which Improvements shall be
constructed pursuant to Article 4) or the Permanent Loan (for Property upon which there are existing Improvements). Borrower shall provide TMCC the Borrowing Notice. Upon
 
 

  notification by Borrower to TMCC of a request for an Acquisition Advance, Borrower shall notify TMCC whether the Acquisition Advance shall be funded under
the Construction Loan or Permanent Loan.
 Section 3.3    Conditions for All Acquisition
Advances.    All Acquisition Advances shall be subject to the following conditions for each particular Property:
 (a)       Borrower shall submit a Borrowing Notice.
 (b)       Except as noted below, an Appraisal dated no earlier than 120 days before the date of such Acquisition Advance shall have been issued
and delivered to TMCC. This requirement shall not apply to a Permanent Advance which is made to pay off a Construction Loan.
 (c)       If applicable, the Purchase Contract has been delivered to TMCC.
 (d)       The Survey has been delivered to TMCC.
 (e)       The Title Policy has been issued and delivered to TMCC.
 (f)       Borrower has delivered to TMCC an Environmental Report, in form, scope and substance acceptable to TMCC, reporting no Hazardous Materials on, under or in the Property in violation
of Environmental Laws.
 (g)       Borrower has provided to TMCC:
 (i)        If the Property is subject to zoning, evidence from the
applicable Governmental Authority that the Property is properly zoned for use as an automobile dealership or related uses.
 (ii)      Evidence that all utility and municipal services required for the occupancy and operation of the Improvements (whether existing or to be constructed as
contemplated herein), including, but not limited to, water supply, storm and sanitary sewer systems, gas, electric and telephone facilities, are available for use and tap-on at the boundaries of the Property and are or will be available in
sufficient amounts for the normal and intended use of the Improvements.
 (iii)     Evidence of compliance with the Restrictions, including, without limitation, evidence that the Property is either a legal and separate lot under any applicable subdivision acts and for tax
assessment purposes, or is exempt from any subdivision act.
 (iv)     Evidence that the Improvements (existing or to be constructed, as applicable) comply with Applicable Laws pertaining to building and zoning requirements.
 (h)       Borrower has provided TMCC such other items as TMCC shall reasonably require.
 
 

  Section 3.4    Limitation on Acquisition Advance.
   Each Acquisition Advance shall be limited so as not to exceed 85% of the lesser of:
 (a)       the Cost of Acquisition (if applicable), or
 (b)       the Appraised Value.
 ARTICLE
4.
 Construction Loan
 Section 4.1    Construction Loan.    The credit facility and funding terms of the Construction Loan shall be governed in
accordance with this Article 4. The provisions of this Article 4 shall apply to each individual
Construction Project.
 Section 4.2    Purpose and Use of Construction Loan.    The Construction Loan shall be used solely for the purchase of Property and the construction of Improvements thereon for full sales and service of new and used automobiles, and all
related dealership facilities.
 Section 4.3    Additional Definitions.
   In addition to other defined terms herein, as used in this Agreement and unless the context otherwise requires, the following terms shall have the respective meanings set forth
below:
 (a)       Architect.   The Architect
for each Construction Project as identified on the Supplement evidencing such Construction Project.
 (b)       Architect Contract.    The contract entered into between Borrower and Architect for the design of the Improvements for a particular
Construction Project, the terms of which must be acceptable to TMCC.
 (c)       As-Built Appraisal.    The estimated value of a Property (with Improvements) upon completion of the Construction Project for that Property. The As-Built Appraisal shall be prepared by an MAI appraiser.
As-Built Appraised Value is the value of the Property reflected in the As-Built Appraisal. Notwithstanding the foregoing, TMCC may adjust the As-Built Appraisal for a Construction Project in its sole
and absolute discretion to establish an adjusted appraised value for a Property (the “Adjusted As-Built Appraised Value”). The Adjusted As-Built Appraised Value of a Property may be used by
TMCC to calculate the Construction Loan Limit, which TMCC may, in its discretion, consider during the approval and funding process for such Construction Project.
 (d)       Budget.    As to each Construction Project, the Cost of Acquisition of the Property plus the Construction Costs estimated by Borrower to be incurred in connection with such Construction Project, as approved by TMCC and as identified on the Supplement evidencing such Construction Project, as may be
amended by Change Orders in accordance with Section 4.16 hereof.
 
 

  (e)       Budgeted Interest.
   As to each Construction Project, the portion of the Construction Costs established for interest identified in the Budget for such Construction Project for the payment of interest accrued on the Construction Loan to be funded for such
Construction Project.
 (f)       Completion Date.
   As to each Construction Project, the date of completion of the Improvements, as evidenced by the issuance of a certificate of occupancy by the appropriate local authorities permitting occupancy of the Improvements. Such certificate of
occupancy may be a temporary certificate subject to completion of items which would not affect the Borrower’s right to occupy the Improvements.
 (g)       Construction Contract.    The contract entered into between Borrower and General Contractor for the construction of the
Improvements for a particular Construction Project, the terms of which must be acceptable to TMCC.
 (h)       Construction Costs.    As to each Construction Project, the costs incurred by Borrower to construct the Improvements on the applicable
Property, as follows: (i) labor and material for grading, site preparation, demolition of existing structures, on-site improvements and required off-site improvements, (ii) any fees paid to the Architect or General Contractor, (iii) other
architectural fees, engineering fees, surveys, fees of the Construction Monitor and utility tap fees, (iv) the cost incurred by Borrower for soil tests of the Property, building permits, environmental testing and similar tests, and (v) Budgeted
Interest. The following costs shall not be included in the Construction Cost: feasibility studies, brokerage fees, appraisal fees, tile insurance premiums, and attorney’s fees, zoning costs,
developer fees, trade fixtures, lifts, paint booths, parts bins, and other automotive related fixtures and equipment.
 (i)        Construction Funding.    As to each Construction Project, that portion of the Construction Costs which will be funded by TMCC under the
Construction Loan. For each Construction Project, prior to any Draw, Borrower and TMCC shall establish in writing the amount of Construction Funding for the applicable Construction Project, which shall be in accordance with the terms
herein.
 (j)        Construction Indebtedness.
   The total amount of principal and accrued interest outstanding from time to time under the Construction Loan.
 (k)       Construction Line of Credit.    The amount available for loan pursuant to Section 4.4
below.
 (l)        Construction Loan Limit.
   The limitations on the amount of Construction Indebtedness under the Construction Loan, as set forth in Section 4.5 below.
 (m)     Construction Monitor.    The person or company engaged by TMCC for each Construction Project, as identified
on the Supplement evidencing such Construction Project.
 (n)       Construction
Project.    The automobile dealership and related Improvements to be constructed on a Property pursuant to the Construction Loan.
 
 

  (o)       Construction Project Loan Amount.    For each Construction Project, the sum of (i) the Acquisition Advance plus (ii) the Construction Funding, subject to the Construction Loan Limit.
 (p)       Construction Project Maturity Date.    As to each Construction Project, the date being the
earlier of (i) 15 months from the date of the Acquisition Advance for such Construction Project, (ii) the date of Substantial Completion, or (iii) December 31, 2007.
 (q)       Construction Promissory Note.    The promissory note
executed by Borrower and payable to the order of TMCC in the principal amount of $50,000,000.00, together with all extensions, renewals, modifications and amendments thereto. The form and substance of the Construction Promissory Note shall be
acceptable to TMCC in TMCC’s sole and absolute discretion.
 (r)       Construction Schedule.    As to each Construction Project, a certified preliminary construction schedule showing a trade-by-trade breakdown of the estimated periods of commencement and completion of the
Improvements.
 (s)       Draw.    As to each
Construction Project, a disbursement from TMCC under the Construction Loan to the Borrower owning such Construction Project pursuant to a Draw Request for payment of Construction Costs.
 (t)        Draw Request.    A written request (on a form approved by TMCC) for a Draw submitted by
Borrower to TMCC, pursuant to Section 4.8(e) below.
 (u)       Draw Termination Date.    November 30, 2007.
 (v)       Engineer’s Contract(s).   All agreements, if any, with the civil, geotechnical, mechanical and structural engineers
for the Improvements.
 (w)     Excess Amount(s).    If
applicable, the amount by which the Construction Indebtedness exceeds the Construction Line of Credit.
 (x)       Final Draw.   The final Draw pursuant to Section 4.11 below.
 (y)       General Contractor.   The general contractor for each
Construction Project as identified on the Supplement evidencing such Construction Project.
 (z)       Holdback.   As to each Construction Project, an amount equal to not less than 10% of the amount of the Construction Costs. TMCC shall retain
from the amount of each Draw Request approved by TMCC 10% of the amount available for such Draw (or such greater percentage if required by applicable state law). The Holdback shall be released to or for the account of Borrower upon payment of the
Final Draw in respect of the applicable Construction Project.
 (aa)     Permits.    All licenses, permits, authorizations and agreements required for the construction, operation, use or occupancy of the Property (as to each Construction Project).
 
 

  (bb)     Plans.   The final working
drawings and specifications for the construction of the Improvements, which must be acceptable to TMCC. The Plans must include an “as-built” survey or plat showing the proposed location of the foundation of the Improvements, showing no
encroachment of the Improvements on any boundary line, easement, building setback line, or other restricted area.
 (cc)     Substantial Completion.   Completion of the Construction Project as evidenced by satisfaction of all of the following: 
 (i)        A temporary certificate of occupancy (or equivalent thereof) has been
issued for the Construction Project.
 (ii)      Except as provided
below, TMCC has received final lien releases or waivers from (i) the General Contractor, (ii) each subcontractor or material supplier whose aggregate contract for the Project exceeds $100,000.00, and (iii) such other evidence of full and final
payment to the other subcontractors and suppliers as may be reasonably requested by TMCC. All such releases or waivers shall be in form and substance acceptable to TMCC, and drafted in conformity with the law of the State and, if applicable, local
jurisdiction in which the applicable Property is located. If a lien, lien claim or lien affidavit has been filed and Borrower is unable to procure a lien release or waiver from such party, Borrower may, in lieu of such release or waiver, provide an
indemnity bond in accordance with the provisions of Section 4.10(b) below, and such bond shall be deemed to satisfy the requirements of this (ii) with respect to such lien claimant.
 (iii)     TMCC has received an “as built” Survey of the Construction Project satisfactory in form and substance to
TMCC.
 (iv)     A certificate of substantial completion on the AIA
Document Form G704 shall have been executed by the Architect, General Contractor and Borrower.
 (dd)     Supplement. A written instrument signed by the applicable Borrower and delivered to TMCC for each Property upon which Improvements are to be constructed hereunder,
and which specifies the (i) legal description and street address of such Property, (ii) Cost of Acquisition, (iii) Construction Costs, (iv) identifies each of the General Contractor and Architect, and contains such other information required or
contemplated herein.
 Section 4.4    Establishment of Construction Line of
Credit.   Subject to the terms and conditions of this Agreement, TMCC hereby establishes a revolving line of credit for Borrower in an amount not to exceed the lesser of:
 (a)       $50,000,000.00, or
 (b)       the Construction Loan Limit.
 Section 4.5    Construction Loan Limits and Restrictions.   The Construction Line of Credit shall be subject to and limited in the following
respects:
 
 

  (a)       Not more than 5 Construction Projects shall subject
to the Construction Loan at any given point in time.
 (b)       The sum of the
unpaid (i) Acquisition Advances funded under the Construction Loan for all Construction Projects plus (ii) the Construction Funding for all Construction Projects, shall not exceed $50,000,000.00. Once
Construction Indebtedness applicable to a particular Construction Project has been refinanced as a Permanent Advance hereunder, the amount of the Construction Indebtedness for that Construction Project shall be deemed to have been repaid and such
amount may be re-borrowed hereunder.
 (c)       The sum of the outstanding balance
under the Construction Loan and Permanent Loan shall not exceed $100,000,000.00.
 (d)       For each individual Construction Project, the sum of (i) the Acquisition Advance plus (ii) the Construction Funding, shall not exceed the lesser
of:
 (i)        85% of the sum of (x) the Purchase Price of
the Property (without regard to any Improvements to be constructed) plus (y) the Construction Costs, or
 (ii)      85% of the As-Built Appraised Value. It is acknowledged that TMCC may, at its election, not require Borrower to provide an As-Built Appraisal; if TMCC does not require an As-Built
Appraisal, the provisions of this Section 4.5(d)(ii) shall not apply.
 (e)       If, for any reason, there exists Excess Amounts, the Construction Line of Credit shall be deemed to include the Excess Amounts for all purposes hereunder, except that Excess
Amounts are temporary only and shall not be deemed to permanently increase the Construction Line of Credit.
 (f)       No Acquisition Advances under the Construction Loan shall be made after 45 months from the Effective Date.
 Section 4.6    Loan Documents.   The Construction Loan shall be evidenced by the Construction Promissory Note and the Loan
Documents executed in connection therewith.
 Section 4.7    Conditions for Acquisition Advances
Under Construction Loan.    In addition to any other conditions herein for Acquisition Advances, Acquisition Advances funded under the Construction Loan shall be
subject to the following conditions and limited in the following respects for each particular Property:
 Borrower shall have delivered to TMCC the following
items:
 (a)       Architect Contract. If required by TMCC, Borrower shall also
deliver to TMCC an assignment of the Architect Contract on a form acceptable to TMCC and executed by the Architect.
 (b)       Budget
 
 

  (c)       Construction Contract.
 (d)       Construction Schedule.
 (e)       Engineer’s Contract(s). If required by TMCC, Borrower shall also deliver to TMCC an assignment of the Engineer’s Contract on
a form acceptable to TMCC and executed by the engineer(s).
 (f)       Permits.
Borrower shall deliver to TMCC a certificate listing all required or necessary Permits for the applicable Construction Project.
 (g)       Plans.
 (h)       A list of all subcontractors and materialmen scheduled to perform work or deliver materials, provided that the aggregate cost for all work or materials to be provided by any such subcontractor or materialman exceeds $50,000.00 with respect to
such Construction Project, in connection with construction of the Improvements, together with a copy of all preliminary lien notices, if any, already filed by any such subcontractors and materialmen.
 Section 4.8    Draws – Limits and Documents.    In
addition to other requirements set forth herein, Draws for Construction Costs shall be governed by the following terms:
 (a)       Frequency.    Draws may be made monthly, upon compliance by Borrower with this Loan Agreement, after actual commencement of construction of the
Improvements, for work actually done during the preceding period.
 (b)       Minimum Amount.    Except for the Final Draw, TMCC shall not be obligated to fund a Draw in an amount less than $50,000.00.
 (c)       Method and Payee.    Except as otherwise provided in this Agreement, or as mutually agreed upon between TMCC and
Borrower, Draws shall be made by wire transfer or check payable to Borrower.
 (d)       Draw Limitations.    Draws are subject to the following limitations:
 (i)        No Draws shall be made until Borrower has provided evidence to TMCC that it has paid, out of its funds (independent from loan proceeds from the Construction Loan) 15% of the
sum of (x) the Cost of Acquisition of the Property (without regard to any Improvements to be constructed) plus (y) the Construction Costs for the applicable Construction Project as estimated in the Budget.
 (ii)      The total amount of Draws available for a particular expense item referenced in the Budget shall
not exceed 100% of the applicable expense item. No reallocation of Draws available for a particular expense item shall be allowed except pursuant to Section 4.15 herein.
 
 

  (iii)     If required under the Applicable Laws of
the State in which the particular Construction Project is located, the Holdback from each Draw shall be increased to ensure compliance with such Applicable Laws. 
 (e)       Draw Request.    Borrower shall deliver to TMCC the Draw Request, with a copy to Construction Monitor, at least 30 days
prior to the date on which a Draw is desired by Borrower, specifying the amount and date of the Draw applied for substantially in the form of an Application and Certificate for Payment (AIA Document G702). 
 (f)       Invoices.    In addition to the Draw Request, Borrower shall deliver to TMCC
and Construction Monitor copies of invoices for work actually performed or materials delivered for which payment is to be made from a Draw, and certificates required hereunder and such other information as TMCC or Construction Monitor may from time
to time require.
 (g)       Last Date for Draws.
   No Draws shall be made after 59 months from the Effective Date.
 Section 4.9    Approval and Payment of Draw Requests. Subject to the satisfaction of the terms and conditions set forth elsewhere herein, the approval and payment of Draws shall be subject to the following terms:
 (a)       Approval of Documents.    TMCC shall have reviewed
and approved the Draw Request and accompanying invoices and documents and Construction Monitor shall have sent a written report to TMCC confirming its approval, indicating, without limitation, (i) that the requisition for funds represents the amount
due for work actually completed and materials actually incorporated into the Property (less the Holdback, as defined herein), and (ii) that the work to be completed does not exceed the amount of the undisbursed portion of the Loan.
 (b)       Approval of Construction.    TMCC or Construction
Monitor shall have reviewed and approved the Plans and shall have inspected the Improvements and reviewed the expenses incurred, and determined that the work has been performed in a good and workmanlike manner in accordance with the Plans, that
construction is progressing within the Construction Schedule, and that the expenses are reasonable and in accordance with the Budget.
 (c)       Casualty Loss.    No part of the Improvements shall have been materially injured or damaged by fire or other casualty unless TMCC shall have
received insurance proceeds sufficient in its judgment to effect the satisfactory restoration thereof and to permit completion prior to the applicable Construction Project Maturity Date.
 (d)       Payment of Draw.    Provided that all terms and conditions for a Draw pursuant to this
Article 4 have been complied with in accordance with the terms hereof, TMCC shall fund a Draw Request within 30 days after submission of both (i) the Draw Request and related documents pursuant to
Section 4.8(e) and (ii) the invoices pursuant to Section 4.8(f).
 (e)       Loan Interest.    Unless paid by Borrower from other funds, TMCC may disburse to itself to pay interest monthly as it
accrues on the Construction Promissory Note, the amount allocated for Budgeted Interest for each Construction Project as being available only for payment of that interest on that Construction Project. Disbursements will be made on behalf of
Borrower
 
 

  to TMCC on the payment dates when interest is due and owing in accordance with the terms of the Construction Promissory Note and will be made by a
bookkeeping entry on TMCC’s records reflecting, as an additional disbursement on a Draw for a Construction Project, an amount equal to the accrued interest due on the relevant payment date. If, after making a Draw for Budgeted Interest as set
forth above, Borrower shall pay the interest with other funds, TMCC will, at Borrower’s request, reimburse Borrower to the extent of the payment, but (i) only to the extent available from funds allocated for Budgeted Interest for that
Construction Project, and (ii) only if all interest owing on other Construction Projects is paid in full. The exhaustion of the amount of Draws available for Budgeted Interest shall not impair the obligation of Borrower to pay interest on the
Construction Loan.
 Section 4.10    Conditions to Draws.   
As a condition precedent to each Draw, in addition to all other requirements herein, Borrower must satisfy the following requirements, if applicable, and deliver to TMCC evidence of such satisfaction:
 (a)       Lien Releases.    Borrower will procure and deliver to
TMCC, if required by TMCC, releases or waivers of mechanics’ liens and receipted bills showing payment of all parties who have furnished materials or services or performed labor of any kind in connection with the construction of any of the
Improvements, which releases or waivers shall pertain to all amounts owing to said parties as reflected in the immediately preceding Draw. All such releases or waivers shall be in form and substance acceptable to TMCC, and drafted in conformity with
the law of the State and, if applicable, local jurisdiction in which the applicable Property is located. However, if Borrower is unable to procure and deliver such a release or wavier from a party who has filed a lien, lien claim or lien affidavit,
Borrower shall be relieved of the requirements of this Section 4.10(a) as to such party if Borrower provides an indemnity bond in accordance with the provisions of Section
4.10(b) herein.
 (b)       Evidence of No
Liens.    Borrower will procure and deliver to TMCC evidence that no mechanic’s or materialman’s lien or other encumbrance has been filed and remains in effect against the Property. However, if a lien,
lien claim or lien affidavit has been filed against Borrower or the Property, Borrower may contest such lien by furnishing to TMCC and Title Company an indemnity bond with a corporate surety satisfactory to TMCC and Title Company (in the form
required by the Title Company and any Applicable Law), or other security acceptable to them, in an amount not less than the amount being contested, plus such additional sums to cover possible costs, interest, and penalties, and provided further that
Borrower shall pay any amount adjudged by a court of competent jurisdiction to be due, with all costs, interest, and penalties thereon, before such judgment becomes a lien on the Property. 
 (c)       Endorsement to Title Policy.    The Title Policy shall be endorsed and
extended, if available under local rules, to cover each Draw with no additional title exception objectionable to TMCC.
 (d)       Foundation Survey.    A foundation survey shall have been furnished to TMCC within 30 days after laying of the foundation of the Improvements,
showing no encroachment of the Improvements on any boundary line, easement, building setback line, or other restricted area.
 
 

  (e)       Material Adverse Effect.
   There shall have occurred no Material Adverse Effect in the physical condition of the Property or the financial condition of Borrower, Guarantor or the General Contractor since the previous Draw made in respect of such Construction
Project, and no event shall have occurred which will give TMCC reasonable cause to believe that the construction of the Improvements cannot be completed by the Construction Project Maturity Date, in accordance with the Plans and the terms of this
Agreement and the Loan Documents.
 Section 4.11     Conditions to Final Draw.
   As a condition precedent to the Final Draw, which shall include the Holdback, in addition to all other requirements herein, Borrower must satisfy the following requirements and, if required
by TMCC, deliver to TMCC evidence of such satisfaction:
 (a)       All conditions
precedent to each of the Draws pursuant to Section 4.10 above shall have been satisfied or waived by TMCC.
 (b)       The Construction Project has achieved Substantial Completion.
 (c)       The Title Policy shall be endorsed and extended, if applicable and available, to (i) delete any exception previously included to account for the pending construction of the
Improvements, (ii) insure that there are no encroachments, and (iii) reflect that no mechanic’s or materialmens’ lien or other encumbrance has been filed. The Title Policy shall contain no additional exception objectionable to
TMCC.
 Section 4.12     State Law Requirements.   
In addition to the provisions set forth above, Borrower and TMCC shall comply with all requirements of Applicable Law. Exhibit 4.11 may contain additional requirements for
Construction Projects of particular states and jurisdictions. From time to time, Exhibit 4.11 may be revised by written notice from TMCC to Borrower to incorporate any requirements of such states and
jurisdictions; however, even if Exhibit 4.11 does not set forth any or all state or local law requirements for constructions loans in that jurisdiction, such requirements shall be deemed incorporated
herein and shall be complied with.
 Section 4.13     Assignment of Construction Contract.    As additional security for the payment of the Construction Loan, Borrower hereby transfers and assigns to TMCC all of Borrower’s rights and interest, but not its obligations,
in, under, and to the Construction Contract, upon the following terms and conditions:
 (a)       Borrower represents and warrants that the copy of any Construction Contract it has furnished to TMCC is a true and complete copy thereof and that Borrower’s interest therein
is not subject to any claim, setoff, or encumbrance.
 (b)       Neither this
assignment nor any action by TMCC shall constitute an assumption by TMCC of any obligation under the Construction Contract, and Borrower shall continue to be liable for all obligations of Borrower thereunder. Borrower hereby agrees to perform all of
its obligations under the Construction Contract. Borrower indemnifies and holds TMCC harmless against and from any loss, cost, liability, or expense (including, but not limited to, attorneys’ fees and expenses) resulting from any failure of
Borrower to so perform.
 
 

  (c)       TMCC shall have the right at any time (but shall
have no obligation), to take in its name or in the name of Borrower, such action as TMCC may at any time determine to be necessary or advisable to cure any default under the Construction Contract or to protect the rights of Borrower or TMCC
thereunder. TMCC shall incur no liability if any action so taken by it or in its behalf shall prove to be inadequate or invalid, and Borrower agrees to hold TMCC free and harmless against and from any loss, cost, liability or expense (including, but
not limited to, attorneys’ fees and expenses) incurred in connection with any such action.
 (d)       Borrower hereby irrevocably constitutes and appoints TMCC as Borrower’s attorney-in-fact, in Borrower’s name or in TMCC’s name, upon the occurrence of and during the
continuance of an Event of Default, to enforce all rights of Borrower under the Construction Contract.
 (e)       Prior to an Event of Default, Borrower shall have the right to exercise its rights as Owner under the Construction Contract, provided that Borrower shall not cancel or amend the
Construction Contract (other than change orders pursuant to Section 4.16) or do or suffer to be done any act which would impair the security constituted by this assignment without the prior written
consent of TMCC.
 (f)       This assignment shall inure to the benefit of TMCC, its
successors and assigns, including any purchaser upon foreclosure of the applicable Deed of Trust, any receiver in possession of the Property, and any corporation formed by or on behalf of TMCC which assumes TMCC’s rights and obligations under
this Loan Agreement.
 Section 4.14     Assignment of Plans.   As additional
security for the payment of the Loan, Borrower hereby transfers and assigns to TMCC all of Borrower’s right, title, and interest in and to the Architectural Contract and Plans and hereby represents and warrants to and agrees with TMCC as
follows:
 (a)       The schedule of the Plans delivered to TMCC is a complete and
accurate description of the Plans.
 (b)       The Plans are complete and adequate
for the construction of the Improvements and there have been no modifications thereof except as described in such schedule. The Plans shall not be materially modified without the prior written consent of TMCC.
 (c)       TMCC may use the Plans for any purpose relating to the Improvements, including but not limited
to inspections of construction and the completion of the Improvements.
 (d)       TMCC’s acceptance of this assignment shall not constitute approval of the Plans by TMCC. TMCC has no liability or obligation whatsoever in connection with the Plans and no responsibility for the adequacy thereof or for the construction
of the Improvements contemplated by the Plans. TMCC has no duty to inspect the Improvements, and, if TMCC should inspect the Improvements, TMCC shall have no liability or obligation to Borrower arising out of such inspection. No such inspection nor
any failure by TMCC to make objections after any such inspection shall constitute a representation by TMCC that the Improvements are in accordance with the Plans or constitute a waiver of TMCC’s right thereafter to insist that the Improvements
be constructed in accordance with the Plans.
 
 

  (e)       This assignment shall inure to the benefit of TMCC,
its successors and assigns, including any purchaser upon foreclosure of the applicable Deed of Trust, any receiver in possession of the Property, and any corporation formed by or on behalf of TMCC which assumes TMCC’s rights and obligations
under this Loan Agreement.
 Section 4.15     Budget. 
 (a)       Budget Restriction.   Except as provided in
Section 4.15(b) below, no Draws will be made for a Construction Project to pay for any item, including interest, if the aggregate amount disbursed for such item exceeds the amount shown therefore on the
Budget for such Construction Project, as the Budget may be amended from time to time as provided herein.
 (b)       Budget Reallocation.    If Borrower will not fully utilize the amount budgeted for any particular line item in the Budget for a Construction
Project, the excess may be reallocated to another line item or line items. In TMCC’s discretion, TMCC may, upon the occurrence of and during the continuation of an Event of Default, in addition to all other rights and remedies of TMCC,
reallocate any funds then remaining under the Budget item for “Overhead Payments”, “Contingency” or similar categories to any other Budget line item.
 (c)       Undisbursed Funds Insufficient to Complete Improvements.    If TMCC shall, in its discretion,
determine that the amount of undisbursed proceeds of the Construction Loan allocated to a Construction Project as set forth in the Budget is less than the amount required to complete and pay for the construction of the Improvements and other items
contemplated by the Budget for such Construction Project, including, without limitation, Budgeted Interest, then, in addition to all other rights and remedies of TMCC, TMCC may decline to make further Draws of the Loan for such Construction Project
until Borrower, upon demand by TMCC, and within 5 days of such demand, shall pay to TMCC money in an amount equal to the total deficiency. Any funds delivered to TMCC hereunder shall be applied to the outstanding balance of the Construction Loan
made for the applicable Construction Project in accordance with the terms of the Construction Promissory Note and shall be made available to be re-advanced in respect of the Construction Project in accordance with the terms hereof.
 Section 4.16     Covenants Pertaining to Construction Projects.   
In addition to the covenants contained elsewhere in this Agreement and in the other Loan Documents, Borrower covenants and agrees as follows:
 (a)       Commencement and Completion of Construction.   As to each Construction Project:
 (i)        Borrower shall designate TMCC as the “Construction Lender” on the application
for any building permits for the construction of the Improvements in accordance with Applicable Laws.
 (ii)      Construction of the Improvements will be performed in a good and workmanlike manner, with materials of high quality, and in substantial accordance with the Plans, except for change
orders approved in writing (if required) by TMCC in accordance with Section 4.16(b) below.
 
 

  (iii)     All such work shall be commenced promptly
and prosecuted with due diligence and will be completed in substantial accordance with the Plans and the Improvements ready for occupancy no later than the Construction Project Maturity Date.
 (iv)     At the request of TMCC, Borrower shall, at Borrower’s sole cost and expense, correct any material
defect in the Improvements or any material departure from the Plans not theretofore approved in writing by TMCC and Construction Monitor if required under Section 4.16(b).
 (v)       During the course of construction, Borrower will comply in all material
respects with the Restrictions and all Permits applicable to the Improvements.
 (vi)     When completed, the Improvements will in all material respects comply with all the Restrictions, all Permits and all requirements of any appropriate board of fire underwriters.
 (vii)    Borrower hereby specifically relieves TMCC of any and all liability or
responsibility relating in any way whatsoever to the construction of the Improvements, including, but not limited to, the work thereon, the material or labor supplied in connection therewith, and any errors, inconsistencies or other defects in the
Plans.
 (b)       Change Orders - Requirements.
  Except as provided below, as to each Construction Project, no change will be made in the Plans as approved by TMCC or in the work described in the Construction Contract without the prior written consent of TMCC. TMCC’s prior written
consent shall not be required for change orders if such change:
 (i)        Would result in the expenditure or reduction of costs of less than 3% of the Construction Costs for a Construction Project, based on the Budget for that Construction
Project.
 (ii)      Together with all prior changes, would result in
an aggregate expenditure or reduction of costs of less than 10% of the Construction Costs for a Construction Project, based on the Budget for that Construction Project.
 (iii)     Would result in an extension of the time to complete construction under the Contract beyond the Construction Project Maturity Date.

(iv)     Would not materially and adversely affect the Improvements or TMCC’s
security for the Loan.
 (c)       Change Orders – Submission.    As to each Construction Project, Borrower shall submit to TMCC and Construction Monitor copies of all change orders and construction change directives which require TMCC’s consent under this Section, together with (i)
evidence satisfactory to TMCC and Construction Monitor that all required approvals of any Governmental Authority have been obtained, and (ii) confirmation of the amount of such change in the Budget resulting therefrom. TMCC shall not consider
approving any change orders unless all other approvals that are required from other parties or pursuant to the Restrictions have been obtained;
 
 

  further, TMCC’s and Construction Monitor’s approval shall not be unreasonably withheld or delayed.
 (d)       Reports.    As to each Construction Project: (i) Borrower shall promptly
furnish, or cause to be promptly furnished, to TMCC copies of all reports prepared by or at the request of Borrower in connection with the construction of the Improvements; and (ii) Borrower shall also furnish such additional data and information
relating to the affairs, assets and liabilities of Borrower or construction of the Improvements as TMCC may from time to time reasonably request.
 (e)       Changes to Budget or Construction Schedule.    Subject to Sections 4.15(b), as to each Construction Project: (i) if from time to time there is any change in (1) the nature and type of expenses and amount thereof as are presently estimated in the Budget, or (2) the Construction Schedule, Borrower shall submit to
TMCC a revised Budget setting forth its good faith estimate of such expenses and the source of payment therefor or a revised Construction Schedule, as appropriate; and (ii) such revised Budget or Construction Schedule must be approved by TMCC, in
its discretion, prior to the revised Budget or Construction Schedule replacing the then current Budget or Construction Schedule.
 Section
4.17    Construction Monitor and Other Consultants.    TMCC, at Borrower’s expense, may employ the services of
Construction Monitor on each Construction Project to act on its behalf during the construction of the Improvements. In addition to the involvement of Construction Monitor in the construction of the Improvements, as elsewhere described in this
Agreement, Construction Monitor shall review and approve all final Plans for the Improvements and any other materials relevant to the construction of the Improvements within 20 days after receipt of such materials. Such review and approval is solely
for the benefit of TMCC and it shall not constitute an assumption of any responsibility or liability of whatsoever kind or character by TMCC or Construction Monitor to Borrower, which hereby acknowledges and agrees that it has no right to and is not
relying upon such review and approval in deciding to enter into this Agreement nor in proceeding with construction of the Improvements or applying for Draws hereunder. TMCC, at Borrower’s expense, may hire such other third party consultants as
it deems reasonably necessary to perform such services as may, from time to time, be required by TMCC in connection with the Construction Loan, this Agreement or the Property.
 Section 4.18  (not used)
 Section
4.19     Interest Rate.    Interest on the outstanding balance of the Construction Loan shall accrue at LIBOR from time
to time in effect plus 2.25%.
 Section 4.20     Payment Terms.   The
Construction Project Loan Amount for any Construction Project shall be due and payable as follows:
 (a)       Monthly Payments.   Interest only shall be due and payable monthly. TMCC may disburse to itself interest to the extent of the Budgeted Interest
for a particular Construction Project as set forth in Section 4.9(e).
 
 

  (b)       Permissive Repayment.
   Borrower may, at any time and without any prepayment fee or premium or notice or penalty, repay all or any part of the Construction Project Loan Amount to TMCC.
 (c)       Maturity of Construction Project Loan Amount.    The entire unpaid principal balance, together
with accrued but unpaid interest, on the Construction Project Loan Amount shall be due and payable on the respective Construction Project Maturity Date.
 (d)       Mandatory Repayment.    The Construction Indebtedness shall be repaid by Borrower to TMCC immediately and without
further notice or demand therefore by TMCC upon the Termination Date of this Agreement set forth herein.
 Section
4.21     Release Provisions.   TMCC will release the lien of the Deed of Trust on a Property provided the following conditions are satisfied:
 (a)       Notice.   Prior to such release, Borrower provides TMCC 30
days advance written notice of its request to have a certain Property released.
 (b)       Information.    If applicable, at TMCC’s request, Borrower shall provide supplemental information that addresses what effect the requested
release might have on the remaining Properties, the operations thereon, or any uses thereof (including public utilities, public access roads and the automobile dealerships).
 (c)       Endorsement to Title Policy.   If applicable, at the time of such release, Borrower shall deliver
to TMCC an endorsement to the Title Policy insuring TMCC’s first lien granted under the Deed(s) of Trust, in form and substance satisfactory to TMCC, assuring that TMCC’s first lien remains in full force and effect as to all Properties
remaining subject to such Deed(s) of Trust, subject only to the Permitted Encumbrances, and is in no way adversely affected by such release, and remains in the full Construction Loan amount.
 (d)       No Violations.    Prior to such release, Borrower shall provide evidence
acceptable and satisfactory to TMCC demonstrating that the requested release will not violate any local, state or other governmental plat act or other governmental regulatory restriction, or any covenant, condition, restriction, limitation, zoning
or other requirement applicable to any other Property.
 (e)       No
Default.    No Event of Default on the part of Borrower or Guarantor shall have occurred and be continuing under the Construction Loan or Permanent Loan.
 (f)       Release Price.    Borrower pays a release amount equal to the then outstanding balance (including
both principal and interest) of the Construction Project Loan Amount pertaining to the applicable Construction Project, or the pro-rata share of outstanding Draws (together with the pro-rata share of accrued interest) if the Construction Project
includes one or more Properties and all are not being released.
 (g)       Expenses.   Borrower will pay TMCC’s reasonable out of pocket expenses incurred in connection with any such release, including but not limited to, escrow fees, legal fees and expenses, appraisal fees,
recording fees and endorsements to TMCC’s Title Policy.
 
 

  ARTICLE 5.
 Permanent
Loan
 Section 5.1    Permanent Loan.    The credit facility and funding terms of the Permanent Loan shall be governed in accordance with this Article 5. The
provisions of this Article 5 shall apply to each individual Permanent Advance.
 Section 5.2    Additional Definitions.    In addition to other defined terms herein, as used in this Agreement and unless the
context otherwise requires, the following terms shall have the respective meanings set forth below:
 (a)       Construction Loan Conversion.    The refinance of a Construction Loan to a Permanent Advance pursuant to Section
5.10 below.
 (b)       Permanent Advance.    An advance under the Permanent Promissory Note for a permitted purpose under Section 5.3 below.
 (c)       Permanent Indebtedness.    The amount of principal outstanding from time to time under the Permanent Loan (or individual
loan, as applicable when referenced below).
 (d)       Permanent Line of
Credit.    The amount available for loan pursuant to Section 5.4 below.
 (e)       Permanent Loan Limit.    The limitations on the amount of Permanent Indebtedness under the Permanent Loan, as set forth
in Section 5.5 below.
 (f)       Permanent Promissory Note.    A Promissory Note executed by Borrower and payable to the order of TMCC in the principal amount of the Permanent Loan, together with all extensions, renewals, modifications and
amendments thereto. The form and substance of the Permanent Promissory Note shall be acceptable to TMCC.
 Section 5.3    Purpose of Permanent Advances.    The proceeds of each Permanent Advance under this Article
5 are to be used by Borrower solely to (i) payoff amounts disbursed under the Construction Loan for various Construction Projects upon their completion, and (ii) acquire Properties (not previously financed by TMCC under the
Construction Loan) (which includes the Cost of Acquisition), and pay such other expenses incurred in connection with the acquisition of such Property, approved by TMCC, including, but not limited to title fees, title insurance premiums, legal
expenses, survey expenses, recording fees, escrow fees, environmental report expenses, organizational expenses, documentary stamp tax and taxes and broker’s commissions. 
 Section 5.4    Establishment of Permanent Line of Credit.    Subject to the
terms and conditions of this Agreement, TMCC hereby establishes a revolving line of credit for Borrower in an amount not to exceed the lesser of:
 (a)       $100,000,000.00, or
 
 

  (b)       the Permanent Loan Limit.
 Section 5.5    Permanent Loan Limits and Restrictions.   
The Permanent Line of Credit shall be subject to and limited in the following respects:
 (a)       The sum of the unpaid: (i) Construction Loan Conversions funded under the Permanent Loan plus (ii) Acquisition Advances funded under
the Permanent Loan, shall not exceed $100,000,000.00. Upon the payment of all or any portion of the Permanent Indebtedness, such amount may be re-borrowed hereunder.
 (b)       The sum of the outstanding balance under the Construction Loan and Permanent Loan shall not exceed $100,000,000.00.
 (c)       For each individual Permanent Advance, such Permanent Advance shall not exceed 85% of the Appraised Value of the
Property.
 (d)       For Construction Indebtedness refinanced under the Permanent
Loan, only the unpaid principal balance (including any Budgeted Interest paid as provided under Section 4.9(e)) of the Construction Indebtedness for a particular Construction Project may be financed under the Permanent Loan.
 (e)       Last Date for Permanent Advances.    No Permanent Advance
shall be made after December 31, 2007.
 Section 5.6    Loan
Documents.    The Permanent Loan shall be evidenced by the Permanent Promissory Note, and the Loan Documents executed in connection therewith.
 Section 5.7    Conditions for Acquisition Advances Under Permanent Loan.
   In addition to any other conditions herein for Acquisition Advances, Acquisition Advances funded under the Permanent Loan shall be subject to the following conditions and limited in the
following respects for each particular Property:
 (a)       Borrower has provided
TMCC with a report from a licensed engineer acceptable to TMCC, in form, scope and substance acceptable to TMCC, reporting that the Improvements have been inspected by the engineer and indicating that the Improvements are structurally sound and
evidence no material defects.
 (b)       For a Permanent Advance to refinance a
Construction Loan for a particular Construction Project, Borrower must have complied with all requirements under Section 4.11.
 Section 5.8    Interest Rate.    Interest on the outstanding balance of
each Permanent Advance shall accrue at LIBOR from time to time in effect plus 2.00%.
 Section 5.9    Payment Terms.    Each Permanent Advance (whether arising as the result of a Construction Loan Conversion or an Acquisition Advance) shall be due and payable as
follows:
 
 

  (a)       Monthly Payments.
   Each Permanent Advance under the Permanent Promissory Note shall be due in equal monthly installments in an amount sufficient to fully amortize the entire principal balance of such Permanent Advance over a 25-year period. Accrued
interest on the unpaid principal balance of each Permanent Advance shall be due and payable monthly on the same date as the monthly principal payments. 
 (b)       Permissive Repayment.    Borrower may, at any time and without any prepayment fee or premium or notice or penalty, repay
all or any part of a Permanent Advance to TMCC.
 (c)       Maturity
Date.    The entire unpaid principal balance, together with accrued but unpaid interest, of the Permanent Loan shall be due and payable on or before December 31, 2012.
 (d)       Mandatory Repayment.    The Permanent Promissory Note shall be repaid by
Borrower to TMCC (i) if, following an Event of Default, TMCC makes written demand for payment prior to such Event of Default being cured, or (ii) upon any other event providing for acceleration in the Loan Documents.
 Section 5.10     Construction Loan Conversion.    Upon request by Borrower and upon satisfaction of the conditions set forth herein, the portion of the Construction Loan applicable to a Construction Project shall be refinanced under the Permanent Loan. In addition to any other requirements
set forth herein, as a condition to a Construction Loan Conversion, Borrower shall satisfy the following requirements:
 (a)       Conversion Notice.    Borrower shall submit the Conversion Notice in the form attached hereto as Exhibit
5.10(a). In addition, Borrower shall submit such other certificates as TMCC may require confirming the satisfaction of all conditions for the Permanent Loan hereunder.
 (b)       Reappraisal of the Property.    No later than two weeks prior to the Loan
Closing Date for such Permanent Advance, Borrower must furnish to TMCC a current Appraisal of the Property as improved, prepared no sooner than 45 days prior to the Loan Closing Date. The Appraised Value of the Property as improved under such
Appraisal shall be the Appraised Value for the purposes of determining the limit on the principal amount of the Permanent Advance under Section 5.5(c) above.
 Section 5.11     Release Provisions.    TMCC will release the lien of
the Deed of Trust on a Property provided the following conditions are satisfied:
 (a)       Notice.    Prior to such release, Borrower provides TMCC 30 days advance written notice of its request to have a certain Property
released.
 (b)       Information.    If
applicable, at TMCC’s request, Borrower shall provide supplemental information that addresses what effect the requested release might have on the remaining Properties, the operations thereon, or any uses thereof (including public utilities,
public access roads and the automobile dealerships).
 
 

  (c)       Endorsement to Title Policy.    If applicable, at the time of such release, Borrower shall deliver to TMCC an endorsement to the Title Policy insuring TMCC’s first lien granted under the Deed(s) of Trust, in form and substance satisfactory to TMCC,
assuring that TMCC’s first lien remains in full force and effect as to all Properties remaining subject to such Deed(s) of Trust, subject only to the Permitted Encumbrances, and is in no way adversely affected by such release, and remains in
the full Permanent Loan amount.
 (d)       No Violations.
  Prior to such release, Borrower shall provide evidence acceptable and satisfactory to TMCC demonstrating that the requested release will not violate any local, state or other governmental plat act or other governmental regulatory
restriction, or any covenant, condition, restriction, limitation, zoning or other requirement applicable to any other Property.
 (e)       No Default.    No Event of Default on the part of Borrower or Guarantor shall have occurred and be continuing under the Construction Loan or
Permanent Loan.
 (f)       Release Price.   
Borrower pays a release amount equal to the then outstanding balance (including both principal and interest) of the Permanent Advance in respect to the Property being released. Upon payment of said amount, the total monthly payment due under the
Permanent Loan will be adjusted to reflect such payment.
 (g)       Expenses.    Borrower will pay TMCC’s reasonable out of pocket expenses incurred in connection with any such release, including but not limited to, escrow fees, legal fees and expenses, appraisal fees,
recording fees and endorsements to TMCC’s Title Policy.
 ARTICLE 6.
 Cross Collateralization
 Section 6.1    Cross-Collateralization.    Subject to Section 6.3 below, all Properties now or hereafter subject to a security
interest or other lien pursuant to any Deed of Trust or any other Security Agreement shall secure all Obligations, and any proceeds of the sale or other disposition of any Property pursuant to any Deed of Trust or other Security Agreement may be
applied to any of the Obligations as TMCC may elect. This agreement for cross collateralization shall constitute and be deemed an amendment to and supplement each Deed of Trust or other Security Agreement now or hereafter executed and shall augment
and be in addition to and not in substitution for any provision of any Deed of Trust or other Security Agreement, and shall not otherwise limit or affect the rights and remedies of TMCC under any such Deed of Trust or other Security
Agreement.
 Section 6.2    Memorandum of Cross Collateralization.
   Upon request by TMCC and to the extent permitted by Applicable Law, the Borrower owning a particular Property shall execute a memorandum, in recordable form sufficient for recording in the
applicable real property or other records where the Property is located, reciting that the liens against that Property secures, in addition to any Obligation recited in the applicable Deed of Trust, the Obligations under this Agreement pursuant to
this cross-collateralization provision. TMCC and Borrower shall execute such affidavits and documents as necessary and permitted under
 
 

  Applicable Law to prevent the taxation of any Deed of Trust in excess of the Construction Project Loan Amount or the applicable Permanent Advance, as the
case may be.
 Section 6.3    California Properties.
   The cross collateralization provisions in Section 6.1 above shall not apply to any loans
secured by Property located in California; therefore, Section 6.1 shall not operate to cause any Property located in California to secure any loans or
other indebtedness not otherwise covered by specific loan instruments executed in connection with any loan secured by Property in California.
 ARTICLE
7.
 Representations and Warranties of Borrower
 In
addition to any other representations and warranties set forth herein, each Borrower, individually and collectively, jointly and severally, represents and warrants to TMCC as follows:
 Section 7.1    Organization, Authority and Qualifications.
 (a)       Each Borrower is a limited liability company or limited partnership, as applicable, duly organized, validly existing and in good standing under the laws of
the jurisdiction of its formation, and each is duly qualified to transact business or own real property in each state or other jurisdiction in which its principal real properties are located or in which it conducts any important or material part of
its business.
 (b)       Each Borrower has or will have the power and authority to
execute, deliver and perform this Agreement and the Loan Documents to which it is a party.
 (c)       The persons signing this Agreement and the Loan Documents on behalf of each Borrower have full authority to execute the same on behalf of said entity, and to bind said entity to
the terms thereof.
 Section 7.2    Authorization and Compliance with Applicable Laws and
Material Agreements.   The execution, delivery and performance of this Agreement and the Loan Documents to which such Borrower is a party, and the borrowings hereunder, by Borrower have been duly authorized by all
requisite action on the part of said entity and will not violate the articles of organization, regulations, partnership agreement or operating agreement, as applicable, of such Borrower, and will not violate any Applicable Law affecting Borrower in
any respect, and will not conflict with, result in a breach of the provisions of, constitute a default under, or result in the imposition of any lien, charge, or encumbrance upon any assets of Borrower pursuant to the provisions of any indenture,
mortgage, deed of trust, franchise, permit, license, note or other agreement or instrument to which Borrower may be bound, other than this Agreement and the Loan Documents to which such Borrower is a party. No approval or consent from any
Governmental Authority or other third party is required in connection with the execution of or performance under this Agreement and the Loan Documents to which it is a party by Borrower. Except to the extent that failure to comply would not have a
Material Adverse Effect, each Borrower has otherwise complied with all Applicable Laws. No Borrower is a party
 
 

  to any agreement which in the opinion of such Borrower does or will have a Material Adverse Effect on the business, operations or condition, financial or
otherwise, of such Borrower.
 Section 7.3    Valid and Binding Obligation.    All of the Loan Documents to which Borrower is a party, will upon execution and delivery by such Borrower, constitute a valid binding obligation of such Borrower, enforceable in
accordance with their respective terms.
 Section 7.4    (not used)
 Section 7.5    Litigation and Judgments.    There are no suits or proceedings pending, or, to the knowledge of Borrower, threatened, against or affecting Borrower that, if adversely determined, would have a Material Adverse Effect on the financial condition or business of Borrower or
on the Collateral owned by Borrower; and there are no proceedings by or before any governmental commission, board, bureau, or other administrative agency pending or to the knowledge of Borrower, threatened against such Borrower, which if adversely
determined, would have a Material Adverse Effect on the business, properties, condition, financial or otherwise of such Borrower. There are no outstanding judgments (final or otherwise) against such Borrower. No event has occurred, including,
without limitation, any litigation or administrative proceedings, and no condition exists or, to the knowledge of such Borrower, is threatened, which (i) might render such Borrower unable to perform its obligations hereunder or under the Loan
Documents to which it is a party or any other document contemplated herein or therein, or, if applicable, might adversely affect such Borrower’s ability to perform the contemplated construction of the Improvements for any Construction Project
owned by such Borrower by the Completion Date, as defined herein, and in accordance with the Budget for such Construction Project, (ii) constitutes or, after notice or lapse of time or both, would constitute an Event of Default, or (iii) might
materially and adversely affect the validity or priority of the liens of the Deed of Trust to which such Borrower is a party or the financial condition of such Borrower.
 Section 7.6    Title to and Perfection of Security Interest in Collateral.    Each Borrower is the owner of all its respective Collateral, free and clear of all liens, security interests, and encumbrances, except the Permitted Encumbrances and those in favor of TMCC, and will execute all Deeds of Trust, Security
Agreements, assignments, financing statements or other documents and take such actions as TMCC may deem necessary or desirable to evidence or perfect its first and prior security interest and lien in Collateral under the Loan Documents to which it
is a party.
 Section 7.7    Existing Leases and Contracts.
   Except as specifically disclosed in writing to TMCC, there are (i) no leases or subleases affecting the Property, and (ii) there are no contracts or agreements affecting the use, operation
or maintenance of the Property, which, upon a foreclosure or deed in lieu of foreclosure, would be binding on TMCC or any purchaser at a foreclosure sale.
 Section 7.8    Restrictions.    Each Borrower is familiar with the Restrictions in respect of the
Property owned by it, and has obtained, or will be able to obtain, all Permits for the ownership and operations of the Improvements and, as applicable, the construction of Improvements. As of the date hereof, there is no violation or asserted
violation of any
 
 

  Restrictions concerning the Property owned by such Borrower or the existing or contemplated use thereof. No Borrower is aware of any action or proceeding
pending or threatened before any Governmental Authority with respect to the validity of any such Permits in respect of the Property owned by it.
 Section
7.9    Zoning.    Each Property is or will be zoned under applicable zoning laws so as to permit the
construction, operation and use of the Improvements for the sale and service of new and used automobiles, and related uses. Adequate water, telephone, gas and electrical service, storm and sanitary sewage facilities and any other required public
utilities are or will be available for and service the Property. The Property fronts on and has adequate access to public streets for pedestrian and motor vehicles. To the Best Knowledge of Borrower, construction of the Improvements and operation of
the Property will not be delayed or impeded by virtue of the requirements under any Applicable Laws. To the Best Knowledge of Borrower, upon completion of the construction of the Improvements, the Property will comply with all Applicable
Laws.
 Section 7.10     No Other Financing Statements.    No UCC-1 or other financing statement covering any assets owned by any Borrower has been executed or is of record in any public office, except those financing statements disclosed on the attached Schedule 7.10 and the financing statements of TMCC.
 Section 7.11     Condemnation.    No taking of the Property or any part thereof through eminent domain, conveyance in lieu thereof, condemnation or similar proceeding is pending
or, to the knowledge of Borrower, threatened by any Governmental Authority.
 Section 7.12     Purpose of Loans;
Use of Proceeds.    Each Borrower has entered into this Agreement for legitimate purposes, and will use the proceeds of the Loans exclusively as set forth in this
Agreement. No Borrower is engaged in illegal activities, and the intended use of the proceeds of the Loans is legally permitted.
 Section
7.13     Ownership of Other Assets; Liens.    Each Borrower has good and indefeasible title or valid leasehold interests
in all their significant or material properties and assets, real and personal, which are owned or used by such Borrower, and none of such properties or assets or leasehold interests of such Borrower are subject to any mortgage, pledge, security
interest, encumbrance, lien or charge of any kind other than the Loan Documents which would materially restrict the manner in which Borrower uses or intends to use such property.
 Section 7.14     Taxes.    Each Borrower has filed all federal and state tax returns or
reports required of it, including but not limited to income, franchise, employment, property and sales taxes, and has paid or made adequate provision for the payment of all taxes which have become due pursuant to such returns or reports or pursuant
to any assessment which has been received, none of such being outstanding and unpaid, and such Borrower knows of no pending investigations of it by any taxing authority, nor of any material pending but unassessed tax liability.
 Section 7.15     (not used)
 Section
7.16     (not used)
 
 

  Section 7.17     (not used)
 Section 7.18     Misrepresentation.    There is no fact which any Borrower has failed to disclose to TMCC, which
materially and adversely affects or is reasonably likely to have a Material Adverse Effect on the business, operation, properties, profits, or condition of such Borrower or the Collateral, or the ability of such Borrower to perform this
Agreement.
 Section 7.19     (not used)
 Section 7.20     Non-Foreign Entity.    Section 1445 of the Internal Revenue Code of 1986, as amended (the
“Code”), provides that a transferee of a real property interest in the United States must withhold tax if the transferor is a foreign person. To inform TMCC that the withholding of tax will
not be required in the event of a disposition of the Property pursuant to the terms of this Agreement, each Borrower hereby certifies that it is not a foreign person, foreign corporation, foreign partnership, foreign trust or foreign estate (as such
terms are defined in the Code and the regulations promulgated thereunder) and that its principal place of business is at the address set forth for notices to Borrower herein. The tax identification number of each Borrower is set forth on
Schedule 1. It is agreed that TMCC may disclose the contents of this certification to the Internal Revenue Service.
 ARTICLE 8.
 Representations and Warranties of Guarantor
 In addition to any other representations and warranties set forth herein, Guarantor represents and warrants to TMCC as follows:
 Section 8.1    Organization, Corporate Authority and Qualifications.
 (a)       Guarantor is a corporation duly organized, validly existing and in good standing under the laws of the jurisdiction of its incorporation, and each is duly qualified to transact
business or own real property in each state or other jurisdiction in which its principal real properties are located or in which it conducts any important or material part of its business.
 (b)       Guarantor has the corporate power and authority to execute, deliver and perform this Agreement and the Guaranty Agreement.

(c)       The persons signing this Agreement and the Guaranty Agreement on behalf of Guarantor
have full authority to execute the same on behalf of said entity, and to bind said entity to the terms thereof.
 Section 8.2    Authorization and Compliance with Laws and Material Agreements.    The execution, delivery and performance of this
Agreement and the Guaranty Agreement by Guarantor have been duly authorized by all requisite corporate action on the part of Guarantor and will not violate the articles of incorporation or bylaws of Guarantor and will not violate any provision of
law, or order of any court or governmental agency affecting Guarantor in any material respect, and will not conflict with, result in a breach of the provisions of, constitute a 
 
 

  default under, or result in the imposition of any lien, charge, or encumbrance upon any assets of Guarantor pursuant to the provisions of any indenture,
mortgage, deed of trust, franchise, permit, license, note or other agreement or instrument to which Guarantor may be bound. No approval or consent from any Governmental Authority or other third party is required in connection with the execution of
or performance under this Agreement and the Guaranty Agreement by Guarantor.
 Section 8.3    Valid and Binding Obligation.    The Guaranty Agreement will upon execution and delivery by Guarantor, constitute a valid binding obligation of Guarantor,
enforceable in accordance with its terms.
 Section 8.4    Financial Condition.    All financial statements (including balance sheets and statements of income and retained earnings) of Guarantor heretofore furnished to TMCC, are complete and correct and fairly
represent the financial condition of Guarantor as at the dates of said financial statements and the results of their operations for the periods ending on said dates. Guarantor has no material contingent obligations, liabilities for taxes, long-term
leases, or unusual forward or long-term commitments not disclosed by, or reserved against in, said balance sheets or the notes thereto; and at the present time, there are no material realized or anticipated losses from any unfavorable commitments of
Guarantor. Said financial statements were prepared in accordance with GAAP consistently maintained throughout the periods involved. Since the date of the latest of such statements, there has been no material adverse change in the financial condition
of Guarantor from that set forth in said statements.
 Section 8.5    Litigation and
Judgments.    There are no suits or proceedings pending, or, to the knowledge of Guarantor, threatened, against or affecting Guarantor that, if adversely determined,
would have a Material Adverse Effect on the financial condition or business of Guarantor; and there are no proceedings by or before any Governmental Authority pending or to the knowledge of Guarantor, threatened against Guarantor, which if adversely
determined, would have a Material Adverse Effect on the business, properties, condition, financial or otherwise of Guarantor. There are no outstanding judgments (final or otherwise) against Guarantor. No event has occurred, including, without
limitation, any litigation or administrative proceedings, and no condition exists or, to the knowledge of Guarantor, is threatened, which (i) might render Guarantor unable to perform its obligations hereunder or under the Guaranty Agreement, or (ii)
constitutes or, after notice or lapse of time or both, would constitute an Event of Default.
 Section 8.6    (not used)
 Section 8.7    (not used)

Section 8.8    (not used)
 Section 8.9    (not used)
 Section 8.10     (not used)

Section 8.11     (not used)
 Section
8.12     (not used)
 
 

  Section 8.13  (not used)
 Section 8.14  Taxes.    Guarantor has filed all
federal and state tax returns or reports required of it, including but not limited to income, franchise, employment and sales taxes, and have paid or made adequate provision for the payment of all taxes which have become due pursuant to such returns
or reports or pursuant to any assessment which has been received, none of such being outstanding and unpaid, and Guarantor knows of no pending investigations of them by any taxing authority, nor of any material pending but unassessed tax
liability.
 Section 8.15  (not used)
 Section 8.16  No Materially Adverse Agreements.    Guarantor is a party to any
agreement which, in the opinion of Guarantor, does or will have a Material Adverse Effect on the business, operations or condition, financial or otherwise, of Guarantor. 
 Section 8.17  (not used)
 Section 8.18  Misrepresentation.    There is no fact which Guarantor has failed to disclose to TMCC, which materially and adversely affects
nor, so far as Guarantor can now foresee, is reasonably likely to have a Material Adverse Effect on the business, operation, properties, profits, or condition of Guarantor, or the ability of Guarantor to perform under the Guaranty
Agreement.
 Section 8.19  (not used)
 Section 8.20  (not used)
 ARTICLE 9.
 Affirmative Covenants
 In addition to any other affirmative covenants and
agreements set forth herein, each Borrower covenants and agrees that, as long as the Obligations or any part thereof is outstanding, unless otherwise allowed by written instrument of TMCC: 
 Section 9.1    (not used)
 Section 9.2    Financial Reports of Lessees.    The following will be furnished TMCC for each
Lessee:
 (a)       Within 90 days after the last day of each fiscal year, and within
45 days after the last day of each fiscal quarter, financial statements including (i) income statements, and (ii) balance sheets, as of the end of such year or quarter, as applicable.
 (b)       From time to time, such further information regarding the financial condition of the Lessee as TMCC may reasonably request.

 

  Section 9.3    Financial Reports of Guarantor.
   The following will be furnished TMCC for Guarantor:
 (a)       Within 90 days after the last day of each fiscal year, and within 45 days after the last day of each fiscal quarter, Guarantor’s annual Form 10-K and quarterly Form 10-Q, as
applicable, filed with the Securities and Exchange Commission. 
 (b)       From time
to time, such further information regarding the financial condition of the Guarantor as TMCC may reasonably request.
 All financial statements delivered
hereunder shall be prepared on the basis of GAAP applied on a consistent basis, and shall be accompanied in each case by a certificate of an officer stating that said financial statements are true and correct and in all material respects and fairly
present the financial condition and results of operations of such Lessee or Guarantor at the date thereof for the period then ended.
 Section 9.4    (not used)
 Section 9.5    Continuing
Business.    Except to the extent failure to do so will not have a Material Adverse Effect, each Borrower shall maintain and continue its present businesses and
maintain its corporate, company or partnership (as applicable) existence in good standing, shall preserve and keep in full force and effect any franchise rights and trade names, and shall pay, before the same become delinquent and before penalties
accrue thereon, all taxes, assessments, and other governmental charges against such Borrower or their property, and any and all other liabilities, except to the extent, and so long as the same are being contested in good faith by appropriate
proceedings, with adequate reserves provided for such payments.
 Section 9.6    Liens,
Etc.    No Borrower will create, incur, or suffer any lien, mortgage, pledge, assignment, or other encumbrance on, or security interest in, any of its properties,
assets, or receivables, now owned or hereafter acquired, securing the Obligations (all such security being herein called “Liens”) without TMCC’s consent, except:
 (a)       Liens to TMCC.
 (b)       Materialmen’s, supplier’s, tax, and other like liens arising in the ordinary course of business and securing obligations
that are not overdue or are being contested in good faith by appropriate proceedings.
 (c)       Purchase money security interests in property now owned or hereafter acquired by such Borrower.
 (d)       Furniture, trade fixtures and equipment purchased in the ordinary course of business.
 Section 9.7    Taxes, Etc.    All taxes, levies, and assessments of
whatever description will be paid by Borrower before interest or penalties accrue thereon, unless the same is being contested in good faith by appropriate proceedings.
 
 

  Section 9.8    Inspection.    Each
Borrower will permit TMCC or its designee to: (a) visit, at any time during normal business hours upon TMCC’s request, each Property owned by it; and (b) inspect during normal business hours all Collateral and any records or documents of such
Borrower or which relate to any Collateral.
 Section 9.9    (not used)
 Section 9.10     Notices.    Borrower shall give to
TMCC, as promptly as possible, notice of:
 (a)       The occurrence of any Event of
Default, or any event which, with the giving of notice or the passage of time, would constitute and Event of Default.
 (b)       Any litigation or proceeding affecting Borrower that is reasonably expected to have a Material Adverse Effect.
 (c)       A Material Adverse Effect.
 (d)       An event or circumstance that would cause any material warranty, representation, covenant or agreement herein to be breached or inaccurate, as applicable.
 Section 9.11     Further Assurances.    At its
costs and expense, upon request of TMCC, Borrower and Guarantor will duly execute and deliver or cause to be duly executed and delivered, to TMCC such further instruments, documents, certificates, financing and continuation statements, and do and
cause to be done such further acts that may be reasonably necessary or advisable in the opinion of TMCC to carry out more effectively the provisions and purposes of this Agreement and the other Loan Documents.
 Section 9.12     Warranties, Representations and Agreements, Renewed and Cumulative.
   Unless subject to a specific notice pursuant to Section 9.10(d), each warranty, representation, covenant and agreement contained in this
Agreement shall be automatically deemed repeated with each Advance and shall be conclusively presumed to have been relied on by TMCC regardless of any investigation made or information possessed by TMCC; subject to any change of fact or
circumstances of which Borrower has previously provided TMCC notice under Section 9.10. The warranties, representations, covenants, and agreements set forth herein shall be cumulative and in addition to
any and all other warranties, representations, covenants, and agreements which Borrower or Guarantor shall give or cause to be given, to TMCC, either now or hereafter.
 ARTICLE 10.

Negative Covenants 
 In addition to any
other covenants and agreements set forth herein, Borrower, individually and collectively, jointly and severally, covenants and agrees that, as long as the Obligations or any part thereof is outstanding, unless otherwise allowed by written instrument
of TMCC, Borrower shall not:
 
 

  Section 10.1     Reorganizations, Acquisitions, Change of Name.
   (a) Merge or consolidate with or into any partnership, trust, or corporation or other entity whatsoever; or (b) sell, lease (other than to Lessees approved by TMCC), transfer, or otherwise dispose of any of its assets which is greater
than ten (10%) of the aggregate total assets of Borrower (except in the ordinary course of business), whether now owned or hereafter acquired. The restrictions in (b) above shall not apply to a sale of a Property for which all Obligations for that
particular Property (whether under the Construction Loan or Permanent Loan) have been or will be paid in full to TMCC at the time of sale.
 Section
10.2     (not used)
 Section 10.3     (not used)
 Section 10.4     Loans and Investments.    Lend or advance money, credit or property to
any Person, or invest in (by capital contribution or otherwise), or purchase or repurchase the stock or indebtedness, of all or a substantial part of the assets or properties of any Person, or agree to do any of the foregoing, except for:

(a)       Direct obligations of, or obligations the principal of and interest on which are
unconditionally guaranteed by, the United States of America and which mature within one year from the date of acquisition thereof.
 (b)       Investments in commercial paper of any corporation with a maturity not in excess of one year from the date of acquisition thereof and rated P-1 or better by Moody’s Investors
Services Inc., or A-1 or better by Standard & Poor’s Corporation.
 (c)       Investments in negotiable or non-negotiable time certificates of deposit and time deposits, with a maturity not in excess of one year from the date of acquisition thereof, issued by or placed with, and money market deposit accounts issued or
offered by any commercial bank organized and existing under the laws of the United States of America or under any states of the United States of America and having a combined capital and undivided surplus of not less than $500,000,000.00,
provided, however, that such certificates of deposit or time deposits at any one bank shall at no time exceed ten percent (10%) of the
undivided capital and surplus of such bank.
 (d)       Advances by any Borrower to
another Borrower, whether constituting capital contributions or indebtedness or otherwise made; provided that no Event of Default is occurring at the time of such advance and no Event of Default
would occur as a result thereof.
 (e)       Acquisition of all or any portion of any
assets or interests of any Person engaged in the automobile dealership business; provided that Borrower and Guarantor deliver prior written notice of any such acquisition to TMCC.
 (f)       (not used)
 Section 10.5     Restriction on Transfer.    Except as expressly permitted pursuant to
this Agreement: (a) O. Bruton Smith and B. Scott Smith, or a related party, shall continue to own directly or indirectly, more than 50% of the combined voting power of the Guarantor’s capital stock ordinarily having the right to vote at an
election of directors, and (b) no Borrower shall,
 
 

  without TMCC’s prior written consent, suffer, permit or enter into (i) any lease of one year or longer, sale, transfer, assignment, agreement for deed,
conveyance, hypothecation or encumbrance, whether voluntary or involuntary, of all or any part of the Property owned by it or any interest therein, or (ii) any sale, assignment, pledge, encumbrance or transfer to a third party of an aggregate of
more than 20% of the ownership interests of any Borrower, if such entity is a corporation, partnership, or limited liability company, or (iii) seizure of the Property or attachment of any lien on the Property, whether voluntary or involuntary, which
has not been removed or bonded over to TMCC’s satisfaction within 30 days of such attachment, then and in such event TMCC may by written notice to Borrower, accelerate and declare the principal balance of the Loans and interest accrued thereon
immediately due and payable notwithstanding any provision to the contrary contained herein or in any of the Loan Documents. Borrower shall notify TMCC promptly in writing of any transaction or event that may give rise to a right of acceleration
hereunder. Any consent by TMCC, or any waiver of an event of default under this Section 10.5, shall not constitute a consent to, or waiver of any right, remedy or power of TMCC under any subsequent
event of default hereunder.
 Section 10.6     Sale of Assets.
   Sell, lease, transfer, exchange or otherwise dispose of any part of its interest in the Collateral or the Property without the prior written consent of TMCC except for sale of inventory in
the ordinary course of business. 
 ARTICLE 11.

(not used)

ARTICLE
12.

Events of Default
 Section 12.1     Events of
Default.    In addition to any other provisions set forth herein included within the definition of a default, the occurrence of any one or more of the following events
shall constitute an “Event of Default”:
 (a)       Payment of Construction Loan.    Failure to make any payments of principal or interest when and as due under the Construction Loan, or any
other instruments evidencing the Construction Loan, and the payment due is not received by TMCC for a period of 10 days after written notice thereof by TMCC to Borrower.
 (b)       Payment of Permanent Loan.    Failure to make any payments of principal or interest when due
under the Permanent Promissory Note or other instruments evidencing the Permanent Loan, and the payment due is not received by TMCC for a period of 10 days after written notice thereof by TMCC to Borrower.
 (c)       Payment of Other Obligations.    Failure to pay, when due, any other
Obligations under any of the Loan Documents, and the payment due is not received by TMCC for a period of 20 days after written notice thereof by TMCC to Borrower.
 
 

  (d)       Noncompliance with Loan Documents.    Failure to perform or observe any of the other agreements, covenants or conditions (i.e., other than the payment of money) contained in this Agreement, in any other Loan Document, and such default shall continue for a period of
30 days after written notice thereof from TMCC to Borrower (unless such default, if curable, requires work to be performed, acts to be done or conditions to be remedied which by their nature cannot be performed, done or remedied, as the case may be,
within such 30 day period and Borrower shall commence to cure such default within such 30 day period and shall thereafter diligently and continuously process the same to completion but in no event shall the period for cure exceed 120 days unless
otherwise agreed by TMCC).
 (e)       Default on Other Debt.    Any Borrower or Guarantor shall fail to pay all or any part of the principal of or interest on any other indebtedness owing to TMCC, when due (whether at maturity, by acceleration or otherwise).
 (f)       Cessation of Construction.    The cessation of the
construction of the Improvements for more than 15 days without the written consent of TMCC. However, delays by reason of Force Majeure shall not be counted as part of said 15 days.
 (g)       Misrepresentations.    Any material representation or warranty made or furnished to TMCC by or on
behalf of any Borrower or Guarantor in this Agreement, any of the other Loan Documents, or any instrument, certificate or financial statement furnished in compliance with or in reference thereto proves to have been false or misleading in any
material respect.
 (h)       (not used)
 (i)        Repudiation of or Default Under Guaranty Agreements.    Any Guarantor
shall (i) revoke or attempt to revoke the Guaranty Agreement signed by such Guarantor, (ii) repudiate such Guarantor’s liability thereunder, or (ii) be in default under the terms thereof, following the expiration of any applicable cure or grace
period.
 (j)        Bankruptcy, Insolvency, Etc.
   The occurrence of any of the following:
 (i)        The appointment of a receiver, trustee, custodian, conservator, or liquidator, or other similar official for any Borrower or Guarantor, any of its property, or any other property of such Borrower or Guarantor.
 (ii)      Any Borrower or Guarantor shall generally not pay its debts as they become due
or shall admit in writing an inability to pay its debts, or shall make a general assignment for the benefit of creditors.
 (iii)     Any Borrower or Guarantor shall commence any case, proceeding or other action seeking relief, reorganization, arrangement, adjustment, liquidation, dissolution or
composition of such Borrower or Guarantor or its respective debts under any debtor relief laws.
 (iv)     Any case, proceeding or other action is commenced against any Borrower or Guarantor seeking to have an order for relief entered against such Borrower or
 
 

  Guarantor, as debtor, or seeking a reorganization, arrangement, adjustment, liquidation, dissolution or composition of such Borrower or
Guarantor or its respective debts under any debtor relief laws, or seeking an appointment of a receiver, trustee, custodian or other similar official for such Borrower or Guarantor or for all or any of its property, or any other property of such
Borrower or Guarantor and such case, proceeding or other action: (i) results in the entry of an order for relief against such Borrower or Guarantor and (ii) remains undismissed for a period of 60 days after commencement.
 (v)       Any Borrower or Guarantor shall have concealed, removed or permitted to be
concealed or removed, any part of its property, with intent to hinder, delay or defraud any of its creditors; or made or suffered a transfer of any of its property which may be fraudulent under any bankruptcy, fraudulent conveyance or similar law;
or shall have made any transfer of its property to or for the benefit of a creditor at a time when other creditors similarly situated have not been paid (unless adequate provision in cash has been made for payment of the similar claim); or shall
have suffered or permitted, while insolvent, any creditor to obtain a lien upon any of the Collateral through legal proceedings which is not vacated within 60 days.
 (vi)     (not used)
 (k)       Franchise Agreements.    Subject to the 120-day time period set forth below, the failure of the Lessee to obtain and maintain approval by (a)
the appropriate original manufacturer or distributor of motor vehicles to sell and service the brand of new motor vehicles contemplated by the parties hereto to be sold by such entity (referred to herein as a “Franchise
Agreement”); and (b) any applicable Governmental Authority agency to purchase, sell, lease, and service motor vehicles as a new and used dealer thereof. If (i) a Lessee’s Franchise Agreement is terminated, or (ii) a
Lessee loses its approval from the applicable Governmental Authority to purchase, sell, lease or service motor vehicles as aforesaid, such event shall not constitute an Event of Default if, not later than 120 days from such termination or loss of
approval, the Lessee’s Franchise Agreement is reinstated or the approval is regained or a new Franchise Agreement subject to TMCC’s reasonable approval is obtained for such Property, as applicable.
 (l)        Cross-Default.   The occurrence of (i) a default under any other Loan
Document and the expiration of any applicable cure or grace period; or (ii) a default under any other agreement between any Borrower or Guarantor and TMCC now existing or hereafter arising and the expiration of any applicable cure or grace period,
will constitute an immediate default under this Agreement, the Loan Documents and all other such agreements.
 ARTICLE 13.

Remedies
 Upon the occurrence of an Event of Default, TMCC shall have, in addition to any other rights or remedies available at law or in
equity, the following rights and remedies:
 
 

  Section 13.1     Termination of Agreement.
   TMCC may terminate this Agreement or any part thereof. By way of example only, TMCC may terminate the Construction Line of Credit under Article 4 and the Permanent Line of Credit under Article 5.
 Section
13.2     Specific Remedies.   TMCC shall have the right to:
 (a)       Institute proceedings to collect all or a portion of the Obligations and to recover a judgment for the same and to collect upon such judgment out of any property of any Borrower
wherever situated.
 (b)       To offset and apply any monies, credits or other
proceeds of property of any Borrower that has or may come into possession or under the control of TMCC against any amount owing to TMCC under this Agreement or any other Loan Document.
 (c)       (not used)
 (d)       (not used)
 (e)       (not used)
 (f)       (not used)
 Section 13.3     Remedies Cumulative.    TMCC shall have all rights
and remedies contained in any other Loan Document, all of which rights and remedies shall be cumulative of those granted herein, or otherwise available at law or in equity. All of TMCC’s rights and remedies may be enforced successively or
concurrently. TMCC’s rights shall include all rights of a secured party under the Uniform Commercial Code applicable in any particular state.
 Section
13.4     Expenses.    Borrower and Guarantor shall pay all expenses and reimburse TMCC for any expenditures, including
reasonable attorney fees and legal expenses, in connection with TMCC’s exercise of any of its rights and remedies under this Agreement.
 Section
13.5     Proceeds.    Proceeds realized by TMCC on the sale or other disposition of the Collateral, after payment of all
expenses incurred by TMCC in enforcing the Obligations or in retaking, holding, preparing for sale or lease, selling, leasing or otherwise disposing of or realizing on the Collateral or the Obligations, shall be applied by TMCC to the remaining
Obligations in such manner as TMCC shall elect.
 Section 13.6     No Agency.
   Nothing herein contained shall be construed to constitute any Borrower or Guarantor as agent of TMCC for any purpose whatsoever, and TMCC shall not be responsible nor liable for any
shortage, discrepancy, damage, loss or destruction of any part of the Collateral wherever the same may be located and regardless of the cause thereof, except to the extent the same results from TMCC’s own gross negligence or willful misconduct.
TMCC shall not, under any circumstances or in any event whatsoever, have any liability for any error or omission or delay of any kind occurring in the settlement, collection or payment of any of the Collateral or any instrument received in payment
thereof or for any damage resulting therefrom, except to the extent the same results from TMCC’s own gross negligence or willful misconduct. TMCC does not by anything herein or in any assignment or otherwise, assume Borrower’s
or
 
 

  Guarantor’s obligations under any contract or agreement assigned to TMCC, and TMCC shall not be responsible in any way for the performance by Borrower
or Guarantor of any of the terms and conditions thereof.
 ARTICLE 14.

Miscellaneous
 Section 14.1     TMCC’s Accounts.    TMCC
shall maintain on its books in accordance with its usual practice an account or accounts with respect to the Loans, which account or accounts shall include, without limitation, (i) the outstanding principal amount of each of the Loans, (ii) the
amount of principal and interest due under each of the Loans and the required payment dates, (iii) all other fees, costs, expenses, losses and indemnities due under this Agreement or any other Loan Document, and (iv) all amounts received by TMCC
with respect to the foregoing. For purposes of any legal action or proceeding arising out of or in connection with this Agreement or any other Loan Document, and for all other purposes, the entries made in such account or accounts maintained by TMCC
pursuant to this Section 14.1 shall create a presumption as to the existence and amounts of the foregoing, absent manifest error.
 Section 14.2     Notices.    Any notice required or permitted to be given hereunder by one
party to the other shall be in writing and the same shall be given and shall be deemed to have been served and given if (i) delivered in person to the address set forth below for the party to whom the notice is given, (ii) placed in the United
States mail by certified mail, return receipt requested, addressed to such party at the address set forth below, (iii) deposited into the custody of FedEx (or other reputable overnight delivery service), addressed to such party at the address set
forth below, or (iv) by telecopy to the telecopy number set forth below. Any notice delivered in person shall be deemed to have been served upon such delivery. Any notice by certified mail shall be deemed to have been served and delivered 3 calendar
days after its deposit into the custody of the U.S. Postal Service. Any notice by overnight courier shall be deemed to have been served and delivered the first Business Day after its deposit into the custody of such overnight courier. Any notice by
telecopy shall be deemed to have been served and delivered upon transmission. All other notices shall be effective and deemed delivered only upon actual receipt. Any party shall have the right to change its address for notice hereunder to any other
location within the continental United States, or to change its telecopy number, by the giving of 30 days’ notice to the other party in the manner set forth above. The addresses of the parties for purposes of notice hereunder are:
  

	 TMCC:
 	  
 	 Toyota Financial Services
 19001 South Western Avenue
 P. O. Box 2958

Torrance, California 90509-2958
 Attn: Ms. Katherine E. Adkins, Esq.
 Telecopy Number: (310) 468-3501
 	  
 

  
 
 

   

	 Borrower and Guarantor:
 	  
 	 Sonic Automotive, Inc.
 5401 East Independence Boulevard
 Charlotte, North
Carolina 28212
 Attn: Mr. Theodore Wright
 Telecopy Number: (704) 536-5116
 	  
 
	  
 	  
 	  
 	  
 
	 With a copy to:
 	  
 	 Sonic Automotive, Inc.
 6415 Idlewild Road
 Suite 109
 Charlotte, North Carolina 28212
 Attn: Mr. Steven Coss, General Counsel
 Telecopy: (704) 927-3412
 	  
 

 Section
14.3     Waiver.    No course of dealing, or any failure by TMCC to insist, or any election by TMCC not to insist, upon
strict performance of any of the terms, provisions or conditions of the Loan Documents shall not be deemed to be a waiver of same or of any other term, provision or condition thereof; and TMCC shall have the right at any time thereafter to insist
upon strict performance of any and all of same. Specifically, no Advance by TMCC when there exists an Event of Default under Article 12 shall in any way preclude TMCC from thereafter declaring such
failure to comply to be an Event of Default hereunder.
 Section 14.4     Survival.
   All representations and warranties contained in this Agreement shall survive the execution of this Agreement and the other Loan Documents, and the making of the Loans.
 Section 14.5     Limitations on Interest.    All
agreements between TMCC, Borrower, whether now existing or hereafter arising and whether written or oral, are hereby limited so that in no contingency, whether by reason of demand for payment or acceleration of the maturity hereof or otherwise,
shall the interest contracted for, charged or received by TMCC exceed the maximum amount permissible under Applicable Law. If, from any circumstance whatsoever, interest would otherwise be payable to TMCC in excess of the maximum lawful amount, the
interest payable to TMCC shall be reduced to the maximum amount permitted under Applicable Law; and if from any circumstance TMCC shall ever receive anything of value deemed interest by Applicable Law in excess of the maximum lawful amount, an
amount equal to any excessive interest shall be applied to the reduction of the principal balance of the Obligations to which such excess pertains and not to the payment of interest, or if such excessive interest exceeds the principal balance such
excess shall be refunded to the applicable Borrower or Guarantor. All interest paid or agreed to be paid to TMCC shall, to the extent permitted by Applicable Law, be amortized, prorated, allocated, and spread throughout the full period until payment
in full of the principal so that the interest hereon for such full period shall not exceed the maximum amount permitted by Applicable Law. This paragraph shall control all agreements between TMCC and Borrower and Guarantor.
 
 

  Section 14.6     Choice of Law.    Except as provided below, this Agreement and the other Loan Documents (except as may be otherwise expressly provided in such other Loan Documents), shall be governed by and construed in accordance with the laws of the
State of California and the laws of the United States applicable to transactions within such State. The Loan Documents executed by a Borrower granting a lien on collateral located in a state other than California shall be governed by the laws of the
state specified in such documents.
 Section 14.7     Venue and Waiver of Jury Trial.
   The parties agree that all actions or proceedings arising in connection with this Agreement and any of the Loan Documents shall be tried and litigated only in the state and federal courts
located in the State of California or, at the sole option of TMCC, in any other court in which TMCC shall initiate legal or equitable proceedings and which has subject matter jurisdiction over the matter in controversy. All the parties to this
Agreement waive any right each may have to assert the doctrine of forum non conveniens or to object to venue to the extent any proceeding is brought in accordance with this Section 14.7. ALL THE PARTIES TO THIS AGREEMENT HEREBY FURTHER JOINTLY AND SEVERALLY WAIVE ANY RIGHT TO TRIAL BY JURY WITH RESPECT TO ANY ACTION, CLAIM, SUIT OR PROCEEDING IN RESPECT OF OR RELATING TO THIS AGREEMENT OR
ANY OTHER LOAN DOCUMENT AND/OR ANY RELATIONSHIP BETWEEN TMCC AND BORROWER AND GUARANTOR.
 Section 14.8     Severability.    If any provision hereof or of any of the other Loan Documents or the application thereof to any person or circumstance shall, for any reason and
to any extent, be invalid or unenforceable, neither the application of such provision to any other person or circumstance nor the remainder of the instrument in which such provision is contained shall be affected thereby, but rather shall be
enforced to the greatest extent permitted by law.
 Section 14.9     Construction.
   This Agreement and each other Loan Document are being entered into by competent and experienced businessmen, represented by counsel, and the parties acknowledge that each party and its
counsel have reviewed and revised this Agreement and the Loan Documents; therefore, the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this
Agreement, the Loan Documents or any amendments or exhibits hereto. The parties intend that all Loan Documents shall be construed and interpreted in a consistent manner.
 Section 14.10     TMCC’s Discretion.    Except as expressly stated otherwise herein,
in any instance hereunder (including any exhibits, schedules, annexes or addenda hereto) where TMCC’s satisfaction, approval or consent or the exercise of TMCC’s judgment is required, or TMCC is to exercise its discretion, the granting or
denial of such satisfaction, approval or consent and the exercise of such judgment or discretion shall be within the sole discretion of TMCC. This provision shall govern any such satisfaction requirements, consents, approvals or exercise of judgment
or discretion required in connection with any of the Loan Documents.
 Section 14.11   No Third Party
Beneficiary.    This Agreement is for the sole benefit of TMCC and Borrower and is not for the benefit of any third party.
 Section 14.12    No Partnership.    In no event shall
TMCC’s rights and interests under the Loan Documents be construed to give TMCC the right to, or be deemed to indicate that TMCC is
 
 

  in control of the business, management or properties of and Borrower or Guarantor, or has power over the daily management functions and operating decisions
made by any Borrower or Guarantor. Nothing contained herein or in any of the other Loan Documents shall be construed as creating joint venture, partnership, tenancy-in-common or joint tenancy arrangement between TMCC, any Borrower and Guarantor. The
relationship of TMCC and each Borrower and Guarantor is and at all times shall be solely that of debtor and creditor.
 Section 14.13   Successors and Assigns.    This Agreement shall be binding upon and inure to the benefit of the parties hereto and their
respective heirs, successors, legal representatives and assigns. However, no Borrower or Guarantor shall assign or encumber this Agreement or any rights herein, it being expressly understood and agreed that the rights of Borrower and Guarantor
hereunder are not assignable.
 Section 14.14   Number and Gender.
   Whenever used herein, the singular number shall include the plural and the plural the singular, and the use of any gender shall be applicable to all genders. The duties, covenants,
obligations, and warranties of each Borrower in this Agreement shall be joint and several obligations of each Borrower.
 Section 14.15   Captions.    The captions, headings, and arrangements used in this Agreement are for convenience only and do not in any
way affect, limit, amplify, or modify the terms and provisions hereof.
 Section 14.16   Time of the
Essence.    Time is of the essence with respect to each and every matter pertaining to performance under this Agreement and of each provision hereof.
 Section 14.17   Executed Copies.    This Agreement may be executed in any number of counterpart copies, each of which counterparts shall be deemed an original for all purposes.
 Section
14.18   Entire Agreement of the Parties.    This Agreement, including all agreements referred to or
incorporated herein and all recitals hereto, is the entire agreement among the parties relating to the subject matter hereof, and supersedes all prior agreements, commitments and understandings among the parties hereto relating to the subject matter
hereof. No variation, modification or changes hereto shall be binding on any party hereto unless set forth in a document executed by such parties or a duly authorized agent, officer or representative thereof. This Agreement shall be deemed effective
as of the date hereof. To the extent that the terms of the documents heretofore evidencing the Construction Loan and Permanent Loan are inconsistent with the terms hereof, or if any contemporaneous or subsequent documents evidencing said loans are
inconsistent with the terms hereof, the terms of this Agreement shall control.
 
 

  EXECUTED to be effective as of the date and year first above written.
  

	            TMCC:
 	  
 	 Toyota Motor Credit Corporation
 
	 
 
 
 	  
 	 By: 
 	 
 /s/ DAVID E. PELLICCIONI
 
	  
 	  
 	  
 	 
 
	  
 	  
 	  
 	 Name: David E. Pelliccioni
 Title: Group Vice
President
 
	  
 	  
 	 
 [Additional Signature Pages to Follow]
 

  

 

   

	 Guarantor:
 	  
 	 Sonic Automotive, Inc.
 
	  
 	  
 	 By: 
 	 
 /s/ THEODORE M. WRIGHT
 
	  
 	  
 	  
 	 
 
	  
 	  
 	  
 	 Name: Theodore M. Wright
 Title:   President
 
	  
 	  
 	 
 [Additional Signature Pages to Follow]
 

  

 

   

	 Borrower:
 	  
 	 SRE Holding, LLC,
 a North Carolina limited liability company
 SRE Alabama - 2,
LLC,
 an Alabama limited liability company
 SRE Alabama - 3, LLC,
 an Alabama limited liability company
 SRE Alabama - 4, LLC,
 an
Alabama limited liability company
 SRealEstate Arizona -1, LLC,
 an Arizona limited liability company
 SRealEstate Arizona - 2, LLC,
 an Arizona limited
liability company
 SRealEstate Arizona - 3, LLC,
 an Arizona limited liability company
 SRealEstate Arizona - 4, LLC,
 an Arizona limited liability
company
 SRealEstate Arizona - 5, LLC,
 an Arizona limited liability company
 SRealEstate Arizona - 6, LLC,
 an Arizona limited liability company

SRealEstate Arizona - 7, LLC,
 an Arizona limited liability company
 SRE California - 1, LLC,
 a California limited liability company
 SRE
California - 2, LLC,
 a California limited liability company
 SRE California - 3, LLC,
 a California limited liability company
 SRE California - 4,
LLC,
 a California limited liability company
 SRE California - 5, LLC,
 a California limited liability company
 SRE California - 6, LLC,
 a California limited liability company
 SRE Colorado - 1, LLC,
 a Colorado limited liability company
 SRE Colorado - 2, LLC,
 a Colorado limited
liability company
 SRE Colorado - 3, LLC,
 a Colorado limited liability company
 SRE Florida - 1, LLC,
 a Florida limited liability company
 SRE Florida - 2, LLC,
 a Florida limited liability company
 SRE Florida - 3, LLC,
 a Florida limited liability company
 SRE Michigan -1,
LLC,
 a Michigan limited liability company
 

   

 

   

	  
 	  
 	 SRE Michigan - 2, LLC,
 a Michigan limited liability company
 SRE Michigan - 3,
LLC,
 a Michigan limited liability company
 SRE Nevada - 1, LLC,
 a Nevada limited liability company
 SRE Nevada - 2, LLC,
 a Nevada
limited liability company
 SRE Nevada - 3, LLC,
 a Nevada limited liability company
 SRE Nevada - 4, LLC,
 a Nevada limited liability company

SRE Nevada - 5, LLC,
 a Nevada limited liability company
 SRE Oklahoma – 1, LLC,
 an Oklahoma limited liability company
 SRE Oklahoma
– 2, LLC,
 an Oklahoma limited liability company
 SRE Oklahoma – 3, LLC,
 an Oklahoma limited liability company
 SRE Oklahoma – 4,
LLC,
 an Oklahoma limited liability company
 SRE Oklahoma – 5, LLC,
 an Oklahoma limited liability company
 SRE South Carolina - 2, LLC,

a South Carolina limited liability company
 SRE South Carolina - 3, LLC,
 a South Carolina limited liability company
 SRE South Carolina - 4, LLC,
 a South Carolina limited liability company
 SRE Tennessee - 1, LLC,
 a Tennessee limited liability company
 SRE Tennessee - 2, LLC,
 a Tennessee
limited liability company
 SRE Tennessee - 3, LLC,
 a Tennessee limited liability company
 SRE Virginia - 1, LLC,
 a Virginia limited liability
company
 
	 
 
 
 	  
 	 By: 
 	 
 /s/ THEODORE M. WRIGHT
 
	  
 	  
 	  
 	 
 
	  
 	  
 	  
 	 Name: Theodore M. Wright
 Title:   Vice
President and Treasurer of each of
               the above companies
 

  

	 
 
 
 	  
 	 Attest:
 	 
 /s/ STEPHEN K. COSS
 
	  
 	  
 	  
 	 
 
	  
 	  
 	  
 	 Stephen K. Coss, Secretary
 of each of the companies
 
	  
 	  
 	  
 
	  
 	  
 	 [Additional Signature Pages to Follow]
 

  
 
 

   

	  
 	  
 	 SRE Georgia - 1, L.P.,
 a Georgia limited partnership
 SRE Georgia - 2,
L.P.,
 a Georgia limited partnership
 SRE Georgia - 3, L.P.,
 a Georgia limited partnership
 

  

	 
 
 
 	  
 	 
 By: 
 	 
 Sonic Automotive of Georgia, Inc.,
 a Georgia corporation, the general partner of each of the above
partnerships
 
	  
 	  
 	  
 	  
 

  

	 
 
 
 	  
 	 By: 
 	 
 /s/ THEODORE M. WRIGHT
 
	  
 	  
 	  
 	 
 
	  
 	  
 	  
 	 Name: Theodore M. Wright
 Title:   Vice President
and Treasurer
 

  

	 
 
 
 	  
 	 Attest:
 	 
 /s/ STEPHEN K. COSS
 
	  
 	  
 	  
 	 
 
	  
 	  
 	  
 	 Stephen K. Coss, Secretary
 
	  
 	  
 
	  
 	 [Additional Signature Pages to Follow]
 

  
 
 

   

	  
 	  
 	 SRE Texas -1, L.P.,
 a Texas limited partnership
 SRE Texas - 2, L.P.,

a Texas limited partnership
 SRE Texas - 3, L.P.,
 a Texas limited partnership
 SRE Texas - 4, L.P.,
 a Texas limited partnership

SRE Texas - 5, L.P.,
 a Texas limited partnership
 SRE Texas - 6, L.P.,
 a Texas limited partnership
 SRE Texas - 7, L.P.,
 a Texas limited partnership
 SRE Texas - 8, L.P.,
 a Texas limited partnership
 
	 
 
 
 	  
 	 
 By: 
 
 
  
 	 
 Sonic of Texas, Inc.,
 a Texas corporation, the
 general partner of each of
the
 above partnerships
 

  

	  
 	  
 	  
 
	 
 
 
 	  
 	 By: 
 	 
 /s/ THEODORE M. WRIGHT
 
	  
 	  
 	  
 	 
 
	  
 	  
 	  
 	 Name: Theodore M. Wright
 Title:   Vice President
and Treasurer
 

  

	 
 
 
 	  
 	 Attest:
 	 
 /s/ STEPHEN K. COSS
 
	  
 	  
 	  
 	 
 
	  
 	  
 	  
 	 Stephen K. Coss, Secretary
 

  
 
 

  EXHIBIT 1.1(kk)

Survey Requirements
 Field Note Description.    The Survey should contain a certified metes and bounds description and should comply with the following requirements:
 (a)       The beginning point should be established by a monument located at the beginning point, or by
reference to a nearby monument.
 (b)       The sides of the Property should be
described by giving the distances and bearings of each.
 (c)       The distances,
bearings, and angles should be taken from a recent instrument survey, or recently re-certified instrument survey, by a licensed Professional Engineer or Registered Surveyor.
 (d)       Curved sides should be described by data including: length of arc, central angle, radius of circle for the arc and chord distance, and
bearing.
 (e)       The legal description should be a single perimeter description
of the entire Property.
 (f)       The description should include a reference to all
streets, alleys, and other rights-of-way that abut the Property surveyed, and the width of all rights-of-way mentioned should be given the first time these rights-of-way are referred to.
 (g)       If the Property surveyed has been recorded on a map or plat as part of an abstract or subdivision, reference to such recording data
should be made.
 Lot and Block Description.    If the Property is included within a properly established, recorded
subdivision or addition, then a lot and block description will be an acceptable substitute for a metes and bounds description, provided that the lot and block description must completely and properly identify the name or designation of the recorded
subdivision or addition and give the recording information therefore.
 Map or Plat.    The Survey should also contain a
certified map or plat showing the following:
 (a)       The plot to be covered by
the Mortgage.
 (b)       The relation of the point of beginning of said plot to the
monument from which it is fixed.
 (c)       Monuments for corners and points of
curves.
 (d)       All easements, showing recording information therefore by volume
and page.
 
Exhibit 1.1(kk) -
1

  (e)       The established building line, if any.
 (f)       All easements appurtenant to said plot.
 (g)       The boundary line of the street or streets abutting the plot and the width of said streets.
 (h)       Encroachments and the extent thereof in terms of distance upon said plot or any easement
appurtenant thereto.
 The Survey should also contain all structures and improvements on said plot with horizontal lengths of all sides and the relation thereof
by distances to (a) all boundary lines of the plot, b) easements, (c) established building lines, and (d) street lines.
 Certification.    The certification for the Property description and the map or plat should be addressed to TMCC (and to the interested title company, if required by the title company), signed by the
surveyor, bearing current date, registration number, and seal, and should be in the following form or its substantial equivalent:
 The undersigned hereby certifies to TMCC that
this survey (i) was made on the ground as per the field notes shown hereon and correctly shows the boundary lines and dimensions and area of the land indicated hereon and each individual parcel thereof indicated hereon; (ii) all monuments
shown hereon actually exist, and the location, size and type of such monuments are correctly shown; (iii) this survey correctly shows the location of all buildings, structures, other improvements and visible items on the subject Property;
(iv) this survey correctly shows the location and dimensions of all alleys, streets, roads, rights-of-way, easements, and other matters of record of which the undersigned has been advised affecting the subject Property according to the legal
description in such easements and other matters (with instrument, book, and page number indicated); (v) except as shown, there are no visible easements, rights-of-way, party walls, drainage ditches, streams, or conflicts, visible encroachments
onto adjoining premises, streets, or alleys by any of said buildings, structures, or other improvements, or visible encroachments onto the subject Property by buildings, structures, or other improvements on adjoining premises; (vi) the distance
from the nearest intersecting street and road is as shown hereon; and (vii) the subject property has direct access to dedicated public roads accepted for maintenance by the entity to which such roads were dedicated.
 
Exhibit 1.1(kk) -
2

  EXHIBIT 3.2

Borrowing Notice
for
Acquisition Advance
 Date:  ________________________, 200____
 To:      Toyota Motor Credit Corporation
19001 So. Western
Avenue, PO Box 2958
Torrance, California 90509-2958
 Re:     Master
Loan Agreement (“Loan Agreement”) dated _________________, 2002, between Toyota Motor Credit Corporation (“TMCC”) and Sonic Automotive, Inc., et al, a Delaware corporation (“Borrower”)
 By delivery of this Borrowing Notice, Borrower hereby requests an Acquisition Advance under the Loan Agreement. The following information is hereby provided to TMCC by Borrower in
accordance with the Section 3.2 of the Loan Agreement:
 1.        Requested amount of Acquisition
Advance:                        $_______________________
 2.        Business Day on which Advance to be
made:                        _______________________
 3.        Current Applicable Loan
Limit:                                       
         $_______________________
 4.        Loan Under Which Made (check one):                 
________            Construction Loan
                                       
                                        
                 ________             Permanent Loan
 Borrower understands that this Borrowing Notice is irrevocable. Borrower hereby represents and warrants to TMCC that no Event of Default has occurred and is continuing under the Loan Agreement and no
event has occurred and is continuing which with the passage of time or giving of notice would mature into an Event of Default. The Borrower hereby restates and reaffirms to TMCC all the representations and warranties contained in the Loan Agreement
the same as if made on the date hereof and fully set forth herein. All capitalized terms used herein unless otherwise defined herein, shall have the meanings ascribed to them in the Loan Agreement.
  

	  
 	  
 	 [Applicable Borrower]
 
	 
 
 
 	  
 	 By: 
 	 
 
 
 
	  
 	  
 	  
 	 
 
	  
 	  
 	  
 	 Name:                                        
                       
 Title:                                        
                         
 

  
 
Exhibit
3.2

  EXHIBIT 4.11

State Law Requirements
 For Construction Projects in Texas:
 In addition to the requirements set forth in Section 4 of the
Master Loan Agreement, the following conditions for Draws shall apply:
 Section 4.8    Additional Conditions to the First Draw.    Borrower and each General Contractor shall have jointly executed and recorded with the county clerk of the county in
which the Property is situated an affidavit of commencement of work, in the form and substance approved by TMCC, which contains the information required by §53.124(c) of the Texas Property Code, provided further that the date of commencement of
work specified in such affidavit shall be subsequent to the date of recordation of the Deed of Trust. Such affidavit shall be executed and recorded after the date the work actually commenced, but not later than the 30th day thereafter.
 Section 4.11     Additional Conditions to Final Draw.   
The Final Draw shall be withheld until 30 days after (i) the “completion” (as that term is defined in §53.106 of the Texas Property Code) of the Improvements, (ii) an affidavit of completion has been filed
with the county clerk of the county in which the Property is located in compliance with §53.106 of the Texas Property Code, and (iii) an second affidavit of completion is provided to TMCC 30 days after the affidavit in (ii) above reflecting
that no lien affidavits have been filed, and no notices have been received by any Person claiming a lien.
 
Exhibit
4.11

  EXHIBIT 5.10(a)

Conversion Notice
 Date:  ___________________________, 200____
 To:      Toyota Motor Credit Corporation
19001 So. Western Avenue, P0 Box 2958
Torrance, California 90509-2958
 Re:     Master Loan Agreement (“Loan Agreement”) dated __________________, 2002, between Toyota
Motor Credit Corporation (“TMCC”) and Sonic Automotive, Inc., et al, a Delaware corporation (“Borrower”)
 By delivery of this Conversion
Notice pursuant to Section 5.10(a) of the Master Loan Agreement, Borrower hereby elects to convert a Construction Project Loan Amount into a Permanent Loan. The following information is hereby provided
to TMCC by Borrower in accordance with the of the Loan Agreement:
 1.        The amount of Construction Funding to be converted (amount shall not exceed the Loan Value for the relevant Property):   $_________________________

2.        Conversion
Date:  __________________________
 3.        Location of Property:  ________________________
 Borrower hereby represents and warrants to TMCC that no Event of Default has occurred or is
continuing under the Loan Agreement and no event has occurred which with the passage of time or giving of notice would mature into an Event of Default. The Borrower hereby restates and reaffirms to TMCC all the representations and warranties
contained in the Loan Agreement the same as if made on the date hereof and fully set forth herein. All capitalized terms used herein unless otherwise defined herein, shall have the meanings ascribed to them in the Loan Agreement.
  

	  
 	  
 	  
 
	  
 	  
 	  
 
	  
 	  
 	 
 
	 
 
 
 	  
 	 By: 
 	 
 
 
 
	  
 	  
 	  
 	 
 
	  
 	  
 	  
 	 Name:                                        
                       
 Title:                                        
                         
 

  
 
Exhibit 5.10
(a)

  SCHEDULE 1

Borrower Information
 Co-Borrowers:
 1.        SRE Alabama - 2,
LLC, an Alabama limited liability company
 2.        SRE Alabama - 3, LLC, an Alabama limited
liability company
 3.        SRE Alabama - 4, LLC, an Alabama limited liability company

4.        SRealEstate Arizona - 1, LLC, an Arizona limited liability company
 5.        SRealEstate Arizona - 2, LLC, an Arizona limited liability company
 6.        SRealEstate Arizona - 3, LLC, an Arizona limited liability company
 7.        SRealEstate Arizona - 4, LLC, an Arizona limited liability company
 8.        SRealEstate Arizona - 5, LLC, an Arizona limited liability company
 9.        SRealEstate Arizona - 6, LLC, an Arizona limited liability company
 10.      SRealEstate Arizona - 7, LLC, an Arizona limited liability company
 11.      SRE California – 1, LLC, a California limited liability company
 12.      SRE California – 2, LLC, a California limited liability company
 13.      SRE California – 3, LLC, a California limited liability company
 14.      SRE California – 4, LLC, a California limited liability company
 15.      SRE California – 5, LLC, a California limited liability company
 16.      SRE California – 6, LLC, a California limited liability company
 17.      SRE Colorado - 1, LLC, a Colorado limited liability company
 18.      SRE Colorado - 2, LLC, a Colorado limited liability company
 19.      SRE Colorado - 3, LLC, a Colorado limited liability company
 20.      SRE Florida - 1, LLC, a Florida limited liability company
 21.      SRE Florida - 2, LLC, a Florida limited liability company
 22.      SRE Florida - 3, LLC, a Florida limited liability company
 23.      SRE Georgia - 1, L.P., a Georgia limited partnership
 24.      SRE Georgia - 2, L.P., a Georgia limited partnership
 25.      SRE Georgia - 3, L.P., a Georgia limited partnership
 26.      SRE Holding, LLC, a North Carolina limited liability company
 27.      SRE Michigan – 1, LLC, a Michigan limited liability company
 28.      SRE Michigan – 2, LLC, a Michigan limited liability company
 29.      SRE Michigan – 3, LLC, a Michigan limited liability company
 30.      SRE Nevada - 1, LLC, a Nevada limited liability company
 31.      SRE Nevada - 2, LLC, a Nevada limited liability company
 32.      SRE Nevada - 3, LLC, a Nevada limited liability company
 33.      SRE Nevada - 4, LLC, a Nevada limited liability company
 34.      SRE Nevada - 5, LLC, a Nevada limited liability company
 35.      SRE Oklahoma – 1, LLC, an Oklahoma limited liability company
 36.      SRE Oklahoma – 2, LLC, an Oklahoma limited liability company
 37.      SRE Oklahoma – 3, LLC, an Oklahoma limited liability company
 
Schedule 1 -
1

  38.      SRE Oklahoma – 4, LLC, an Oklahoma limited liability company

39.      SRE Oklahoma – 5, LLC, an Oklahoma limited liability company
 40.      SRE South Carolina -2, LLC, a South Carolina limited liability company
 41.      SRE South Carolina - 3, LLC, a South Carolina limited liability company
 42.      SRE South Carolina - 4, LLC, a South Carolina limited liability company
 43.      SRE Tennessee - 1, LLC, a Tennessee limited liability company
 44.      SRE Tennessee - 2, LLC, a Tennessee limited liability company
 45.      SRE Tennessee - 3, LLC, a Tennessee limited liability company
 46.      SRE Texas - 1, L.P., a Texas limited partnership
 47.      SRE Texas - 2, L.P., a Texas limited partnership
 48.      SRE Texas - 3, L.P., a Texas limited partnership
 49.      SRE Texas - 4, L.P., a Texas limited partnership
 50.      SRE Texas - 5, L.P., a Texas limited partnership
 51.      SRE Texas - 6, L.P., a Texas limited partnership
 52.      SRE Texas - 7, L.P., a Texas limited partnership
 53.      SRE Texas - 8, L.P., a Texas limited partnership
 54.      SRE Virginia - 1, LLC, a Virginia limited liability company
 
Schedule 1 -
2

  SCHEDULE 7.10

Financing Statements
  
 
Schedule 7.10Promissory Note (Revolving Line of Credit Construction Loan)

  EXHIBIT 10.11
 PROMISSORY
NOTE
(Revolving Line of Credit Construction Loan)
    

	 $50,000,000.00
 	  
 	 December 31, 2002
 	  
 
	  
 	  
 	  
 	  
 
	 Borrower:
 	  
 	 The Entities executing this Note in the signatures below
 	  
 
	  
 	  
 	  
 	  
 
	 Borrower’s Address for Notice:
 	  
 	 5401 East Independence Boulevard
 Charlotte, North Carolina 28212
 	  
 
	  
 	  
 	  
 	  
 
	 Lender:
 	  
 	 Toyota Motor Credit Corporation
 	  
 
	  
 	  
 	  
 	  
 
	 Lender’s Address for Payment:
 	  
 	 19001 South Western Avenue
 Torrance, California 90509-2958
 	  
 
	  
 	  
 	  
 	  
 
	 Promise to Pay:
 	  
 	  
 	  
 

 For value received, the undersigned Borrower promises to pay to the order of Lender the sum of Fifty Million and No/100 Dollars ($50,000,000.00), to the extent advanced by Lender, together with interest on the unpaid balance of such amount,
in lawful money of the United States of America, in accordance with all the terms conditions and covenants set forth below. For purposes of this Note, “Borrower” shall include all the entities executing this Note as set forth
below.
 Definitions: Capitalized terms used in this Note and not defined herein shall have the meanings assigned to such terms in
the Loan Agreement (defined below). In addition, the following terms shall have the meanings set forth below:
 Acquisition Advance Termination
Date – September 30, 2006.
 Advance – Each disbursement of loan proceeds under this Note pursuant
to the Loan Agreement (unless otherwise noted herein, an “Advance” shall be deemed to include (i) an Acquisition Advance for the purchase of Property under Section 3.1 of the Loan Agreement, (ii) a “Draw” under Section 4.3(s) of
the Loan Agreement, and (iii) a disbursement for Budgeted Interest under Section 4.9(e) of the Loan Agreement and as set forth below).
 Applicable
Rate – A varying or fluctuating rate per annum that is equal to LIBOR plus two and one-quarter percent (2.25%). LIBOR is initially determined on the date of the applicable Advance. LIBOR shall be adjusted, as necessary,
as of first calendar day of each month, based on the LIBOR rate in effect as of the last Business Day of the preceding month.
 Construction Project Loan
Maturity Date - As to each Construction Project Loan Amount, the date being the earlier of (i) 15 months from the date of the Acquisition Advance for
 
 

  such Construction Project, (ii) the date of Substantial Completion, or (iii) the Loan Maturity Date.
 Default Interest Rate – The Maximum Lawful Rate, or if no such Maximum Lawful Rate is established by applicable law, then the Applicable Rate plus three percent (3%)
per annum.
 Draw Termination Date – November 30, 2007.
 LIBOR - The London Interbank Offered Rate for one (1) month deposits, as published by The Wall Street Journal in its “Money Rates”
section. Should the method of establishing LIBOR, or the publication of the London Interbank Offered Rates for one (1) month deposits in The Wall Street Journal cease or be abolished, then LIBOR shall
be based on a comparable index selected by Lender.
 Loan Agreement - Master Loan Agreement dated as of even date herewith among
Borrower, Lender and Sonic Automotive, Inc. This Note is issued pursuant to the terms of the Loan Agreement.
 Loan Documents –
This Note, the Loan Agreement, the Security Documents, and any other instruments evidencing this Note or otherwise governing, guaranteeing or pertaining to the loan evidenced by this Note.
 Loan Maturity Date – December 31, 2007.
 Maximum Lawful Amount - The
maximum, nonusurious and lawful contractual amount of interest, that may collected or received by Lender under applicable state or federal law.
 Maximum
Lawful Rate - The maximum, nonusurious and lawful contractual rate of interest that may be charged by Lender under applicable state or federal law.
 Permanent Note - The Promissory Note dated of even date herewith executed by Borrower and payable to Lender in the principal amount of $100,000,000.00.
 Principal Balance  - The aggregate unpaid principal balance of all Advances, outstanding from time to time.
 Security Documents – All deeds of trust, mortgages, security agreements, guaranties, pledges, assignments, or any other instruments securing this Note.
 TERMS OF NOTE
 Interest and Principal Provisions:
 (a)       Interest Accrual: The Principal Balance of this Note advanced but from time to time
remaining unpaid prior to maturity shall bear interest at the Applicable Rate, but never
 
 

  greater than the Maximum Lawful Rate. The Applicable Rate will automatically fluctuate upward or downward with changes to LIBOR in accordance with the
provisions herein, without notice to Borrower or any other person. The (i) past due installments of principal and interest on this Note, and (ii) entire Principal Balance after acceleration of the Principal Balance, shall bear interest at a per
annum rate equal to the Default Interest Rate.
 (b)      Payment Terms: From the date hereof to and including the Loan Maturity Date, this Note shall be due and payable as follows:
 (i)        Interest - Accrued interest on the unpaid Principal Balance outstanding shall be due and payable monthly. On the Loan Maturity Date, all accrued but unpaid interest shall be
due and payable. Budgeted Interest may be paid as provided in (ii) below.
 (ii)       Budgeted Interest – Unless paid by Borrower from other funds, Lender may disburse to itself to pay interest monthly as it accrues on this Note, the amount allocated for
Budgeted Interest for each Construction Project as being available only for payment of that interest on that Construction Project. Disbursements will be made on behalf of Borrower to Lender on the payment dates when interest is due and owing in
accordance with the terms of this Note and will be made by a bookkeeping entry on Lender’s records reflecting, as an additional disbursement hereunder, an amount equal to the accrued interest due on the relevant payment date. If, after making a
disbursement for Budgeted Interest as set forth above, Borrower shall pay the interest with other funds, Lender will, at Borrower’s request, reimburse Borrower to the extent of the payment, but (i) only to the extent available from funds
allocated for Budgeted Interest for that Construction Project, and (ii) only if all interest owing on other Construction Projects is paid in full. The exhaustion of the amount of Draws available for Budgeted Interest shall not impair the obligation
of Borrower to pay interest on the Construction Loan.
 (iii)     Principal
– On each Construction Project Loan Maturity Date, a principal installment equal to the aggregate amount of all outstanding Advances made for such Construction Project shall be due and payable.
 (iv)      Loan Maturity Date – On the Loan Maturity Date, a final installment, which shall include all
unpaid amounts of the Principal Balance and interest accrued thereon, and any and all other payments due under this Note, shall be due and payable.
 (v)       Due Dates and Application of Payments – The monthly payments of interest shall commence on the first day of the first month
following funding of the first Advance hereunder, and shall continue regularly and monthly thereafter on the first day of each succeeding month. The amount of each of such payments in respect of the outstanding Advances shall be aggregated each
month and shall be due as one monthly installment. Each installment shall be applied first to accrued but unpaid interest and the balance to reduction of the Principal Balance.
 
 

  Advances and Prepayments:
 (a)       Revolving Line of Credit: This Note shall evidence Borrower’s indebtedness for Advances from time to time made under a revolving credit line
pursuant to the Loan Agreement, which indebtedness may from time to time be decreased, increased, paid in full and then renewed. Interest will accrue only from the date that Advances are made pursuant to the Loan Agreement, and the liability of the
undersigned is limited to the Principal Balance from time to time actually disbursed pursuant to the Loan Agreement, plus unpaid interest actually accrued on such principal, plus any expenses or other charges as more fully provided in this Note, the
Loan Agreement and any other Loan Documents. This Note shall evidence all such indebtedness and this Note and all lien instruments securing it and the liens and security interests thereunder shall remain in effect until this Note is formally
terminated in writing, and this Note and such lien instruments, liens and security interests shall not otherwise be terminated by payment of all or any part of the indebtedness hereby represented. Lender shall, and is hereby authorized by Borrower
to, endorse on Schedule A attached hereto and made a part hereof (or on a continuation of such schedule) an appropriate notation evidencing the date and amount of each Advance, the Property being funded
with the Advance, and any payments made thereon; provided, however, that the failure of Lender to make such a notation on this Note shall not affect any obligation of Borrower under this Note. Any such notation shall be prima facie evidence as to
the date, amount, and monthly payment of such Advance or payment.
 (b)      Prepayment: Borrower may prepay the Principal Balance in whole or from time to time in part, at any time, upon payment of interest accrued on the Principal Balance outstanding through the day of prepayment and all
other charges due hereunder and under the Security Documents, without premium. All payments and prepayments received by Lender prior to an Event of Default, including, without limitation, any condemnation awards or insurance proceeds received under
the Security Documents which Lender is permitted to apply on the indebtedness evidenced hereby will be applied first to accrued unpaid interest on the Principal Balance at the Applicable Rate, and then:
 (i)        in the case where such prepayment is not made in connection with the release of a
Property pursuant to Section 4.21 of the Loan Agreement, but such prepayment is attributable to a condemnation awards or to insurance proceeds relating to a specific Property, to the outstanding balance
of Advances attributable to that Property, in the order in which such Advances were made,
 (ii)       in the case where such prepayment is not made in connection with the release of a Property pursuant to Section 4.21 of the Loan Agreement, but such prepayment is not attributable to a condemnation awards or to insurance proceeds relating to a specific Property, to the outstanding principal balance of all Advances then remaining unpaid in the order in which the Advances were
made, and
 (iii)     in the case where such prepayment is made in
connection with the release of a Property pursuant to Section 4.21 of the Agreement, to the outstanding principal balance of the Advance attributable to the Property being released.
 
 

  Any prepayments made in connection with the release of any Property shall be noted on Schedule B attached hereto and made a part hereof. Lender shall, and is hereby authorized by Borrowers to, endorse on Schedule B an appropriate notation evidencing the date and amount of each such
prepayment.
 (c)       Limitations on Advances: The Loan
Agreement contains limitations on the amount of Advances which may be made hereunder, which includes a limitation on the combined amount of unpaid principal under this Note and the Permanent Note.
 (d)      Acquisition Advance Termination Date: No Advances for an Acquisition Advance for the purchase
of Property shall be made after the Acquisition Advance Termination Date.
 (e)       Draw Termination Date: No Advances for Draws shall be made after the Draw Termination Date.
 Default and Waiver Provisions:
 (a)       Events of Default and Acceleration of Maturity: Lender may,
subject to any notice requirements in the Loan Agreement, declare the entire unpaid Principal Balance and all accrued and earned but unpaid interest at once due and payable upon the occurrence of an Event of Default. 
 (b)      Waiver by Borrower: Except as expressly set forth in the Loan Agreement,
Borrower and all other parties liable for this Note waive demand, notice of presentment, presentment for payment, notice of nonpayment, protest, notice of protest, grace, notice of dishonor, notice of intent to accelerate, notice of acceleration,
and diligence in collection.
 (c)       Non-Waiver by Lender: Any previous extension of time, forbearance, failure to pursue some remedy, or acceptance of partial payment by Lender, before or after maturity, does not constitute a waiver by Lender of the existence of any event of default nor of its
right to strictly enforce the collection of this Note according to its terms. Lender shall not be deemed, by any act of omission or commission, to have waived any of its rights or remedies hereunder unless such waiver is in writing and signed by
Lender and, then, only to the extent specifically set forth in the writing. A waiver with reference to one event shall not be construed as continuing or as a bar to or waiver of any right or remedy as to a subsequent event.
 (d)      Other Remedies Not Required: Lender shall not be required to first file
suit, exhaust all remedies, or enforce its rights against any security in order to enforce payment of this Note.
 (e)       Joint and Several Liability: Each Borrower who signs this Note, and all of the other parties liable for the payment of this Note, such as guarantors,
endorsers, and sureties, are jointly and severally liable for the payment of this Note.
 (f)       Attorney’s Fees: If Lender requires the services of an attorney to enforce the payment of this Note or the performance of the other Loan Documents,
or if this Note is collected
 
 

  through any lawsuit, probate, bankruptcy, or other judicial proceeding, Borrower agrees to pay Lender an amount equal to its reasonable attorney’s fees
and other collection costs. This provision shall be limited by any applicable statutory restrictions relating to the collection of attorney’s fees.
 Miscellaneous
Provisions:
 (a)       Usury Disclaimer: All
agreements between Lender and Borrower, whether now existing or hereafter arising and whether written or oral, are hereby limited so that in no contingency, whether by reason of demand for payment or acceleration of the maturity hereof or any other
circumstance whatsoever, shall the interest contracted for, charged or received by Lender exceed the Maximum Lawful Amount. If, from any circumstance whatsoever, interest would otherwise be payable to Lender in excess of the Maximum Lawful Amount,
the interest payable to Lender shall be reduced to the Maximum Lawful Amount; and if from any circumstance Lender shall ever receive any interest in excess of the Maximum Lawful Amount, an amount equal to any excessive interest shall be applied to
the reduction of the Principal Amount and not to the payment of interest, or if such excessive interest exceeds the unpaid Principal Amount such excess shall be refunded to Borrower. All interest paid or agreed to be paid to Lender shall, to the
extent permitted by applicable law, be amortized, prorated, allocated, and spread throughout the full period until payment in full of the Principal Amount (including the period of any renewal or extension hereof) so that the interest hereon for such
full period shall not exceed the Maximum Lawful Amount. For purposes of this paragraph, the term interest shall include all considerations and amounts that constitute interest under applicable usury law. This paragraph shall control all agreements
between Borrower and Lender.
 (b)      Application of Payments: Except as otherwise expressly set forth herein or in the Loan Agreement, all payments on the indebtedness evidenced by this Note and by the other Loan Documents, other than regularly scheduled payments, shall be applied to such indebtedness
in such order and manner as Lender may from time to time determine in its absolute discretion.
 (c)       Subsequent Holder: All references to Lender in this Note shall also refer to any subsequent owner or holder of this Note by transfer, assignment,
endorsement or otherwise.
 (d)      Successors and Assigns:
The provisions of this Note shall be binding upon and for the benefit of the successors, assigns, heirs, executors and administrators of Lender and Borrower.
 (e)       Other Parties Liable: All promises, waivers, agreements and conditions applicable to Borrower shall likewise be applicable to and
binding upon any other parties primarily or secondarily liable for the payment of this Note, including all guarantors, endorsers and sureties.
 (f)       Modifications: Any modifications agreed to by Lender relating to the release of liability of any of the parties primarily or secondarily liable for the
payment of this Note, or relating to the release, substitution, or subordination of all or part of the security for this Note, shall in no way constitute a release of liability with respect to the other parties or security not covered by such
modification.
 
 

  (g)      Borrower’s Address for Notice: All notices required to be sent by Lender to Borrower shall be sent by United States Mail, postage prepaid, to Borrower’s Address for Notice stated on the first page of this Note, until Lender shall receive written notification from
Borrower of a new address for notice.
 (h)      Lender’s Address for
Payment: All sums payable by Borrower to Lender shall be paid at Lender’s Address for Payment stated on the first page of this Note, until Lender shall notify Borrower of a new address for payment.
 (i)       Applicable Law: This Note has been executed and delivered, and shall
be construed, in accordance with the applicable laws of the State of California and the United States of America.
 (j)       Time of Essence: Time is of the essence in Borrower’s performance of all duties and obligations imposed by this Note.
 (k)      Partial Invalidity: In the event any one or more of the provisions hereof
shall be invalid, illegal or unenforceable in any respect, the validity of the remaining provisions hereof shall be in no way affected, prejudiced or disturbed thereby.
 (l)       Gender: Whenever used, the singular shall include the plural, the plural shall include the singular, and
the words “Lender”, “Borrowers” and “Borrower” shall be deemed to include their respective heirs, administrators, executors, successors and assigns.
 
 

     

	 Borrower’s Signature:
 	 SRE Holding, LLC, 
 a North Carolina limited liability company
 SRE Alabama - 2,
LLC, 
 an Alabama limited liability company
 SRE Alabama - 3, LLC, 
 an Alabama limited liability company
 SRE Alabama - 4, LLC, 
 an
Alabama limited liability company
 SRealEstate Arizona -1, LLC, 
 an Arizona limited liability company
 SRealEstate Arizona - 2, LLC, 
 an Arizona limited
liability company
 SRealEstate Arizona - 3, LLC, 
 an Arizona limited liability company
 SRealEstate Arizona - 4, LLC, 
 an Arizona limited liability
company
 SRealEstate Arizona - 5, LLC, 
 an Arizona limited liability company
 SRealEstate Arizona - 6, LLC, 
 an Arizona limited liability
company
 SRealEstate Arizona - 7, LLC, 
 an Arizona limited liability company
 SRE California - 1, LLC, 
 a California limited liability company

SRE California - 2, LLC, 
 a California limited liability company
 SRE California - 3, LLC, 
 a California limited liability company
 SRE
California - 4, LLC, 
 a California limited liability company
 SRE California - 5, LLC, 
 a California limited liability company
 SRE California - 6, LLC,

 a California limited liability company
 SRE Colorado - 1, LLC, 
 a Colorado limited liability company
 SRE Colorado - 2, LLC, 
 a
Colorado limited liability company
 SRE Colorado - 3, LLC, 
 a Colorado limited liability company
 SRE Florida - 1, LLC, 
 a Florida limited liability
company
 SRE Florida - 2, LLC, 
 a Florida limited liability company
 SRE Florida - 3, LLC, 
 a Florida limited liability company
 SRE
Michigan -1, LLC, 
 a Michigan limited liability company
 SRE Michigan - 2, LLC,
 

 
 

     

	  
 	  
 	 a Michigan limited liability company
 SRE Michigan - 3, LLC,
 a Michigan limited
liability company
 SRE Nevada - 1, LLC, 
 a Nevada limited liability company
 SRE Nevada - 2, LLC, 
 a Nevada limited liability company
 SRE Nevada - 3, LLC, 
 a Nevada limited liability company
 SRE Nevada - 4, LLC, 
 a Nevada limited liability company
 SRE Nevada - 5, LLC, 

a Nevada limited liability company
 SRE Oklahoma – 1, LLC,
 an Oklahoma limited liability company
 SRE Oklahoma – 2, LLC,
 an Oklahoma
limited liability company
 SRE Oklahoma – 3, LLC,
 an Oklahoma limited liability company
 SRE Oklahoma – 4, LLC,
 an Oklahoma limited liability
company
 SRE Oklahoma – 5, LLC,
 an Oklahoma limited liability company
 SRE South Carolina - 2, LLC, 
 a South Carolina limited liability
company
 SRE South Carolina - 3, LLC, 
 a South Carolina limited liability company
 SRE South Carolina - 4, LLC, 
 a South Carolina limited liability
company
 SRE Tennessee - 1, LLC, 
 a Tennessee limited liability company
 SRE Tennessee - 2, LLC, 
 a Tennessee limited liability company
 SRE Tennessee - 3, LLC, 
 a Tennessee limited liability company
 SRE Virginia - 1, LLC, 
 a Virginia limited liability company
 
	  
 	 
 
 
 	 By: 
 	    
 
 /s/ THEODORE M.
WRIGHT
 
	  
 	  
 	  
 	 
 
	  
 	  
 	 Name: 
 	 Theodore M. Wright
 
	  
 	  
 	 Title: 
 	 Vice President and Treasurer each of
 the above Companies
 

	 
 
 
 	 Attest: 
 	 
 /s/ STEPHEN K. COSS
 
	  
 	  
 	 
 
	  
 	  
 	  
 	 Stephen K. Coss, Secretary
 of each of the Companies
 
				

 
 

    

	  
 	 SRE Georgia - 1, L.P., 
 a Georgia limited partnership
 SRE Georgia - 2, L.P.,

 a Georgia limited partnership
 SRE Georgia - 3, L.P., 
 a Georgia limited partnership
 
	 
 
 
 	 
 By: 
 	 
 Sonic Automotive of Georgia, Inc., 
 a Georgia corporation, the General Partner of each of

the above Partnerships
 
 
 

   

	  
 	 
 
 
 	 By: 
 	    
 
 /s/ THEODORE M.
WRIGHT
 
	  
 	  
 	  
 	 
 
	  
 	  
 	 Name: 
 	 Theodore M. Wright
 
	  
 	  
 	 Title: 
 	 Vice President and Treasurer
 

	  
 	 
 
 
 	 By: 
 	 
 /s/ STEPHEN K. COSS
 
	  
 	  
 	  
 	 
 
	  
 	  
 	  
 	 Stephen K. Coss, Secretary
 

  
 
 

     

	  
 	 SRE Texas -1, L.P., 
 a Texas limited partnership
 SRE Texas - 2, L.P., 

a Texas limited partnership
 SRE Texas - 3, L.P., 
 a Texas limited partnership
 SRE Texas - 4, L.P., 
 a Texas limited partnership

SRE Texas - 5, L.P., 
 a Texas limited partnership
 SRE Texas - 6, L.P., 
 a Texas limited partnership
 SRE Texas - 7, L.P., 
 a Texas limited partnership
 SRE Texas - 8, L.P., 
 a Texas limited partnership
 
	 
 
 
 	 
 By: 
 	 
 Sonic of Texas, Inc.,
 a Texas corporation, the General Partner of each of the 
 above Partnerships
 

	  
 	  
 	 By: 
 	    
 
 /s/ THEODORE M.
WRIGHT
 
	  
 	  
 	  
 	 
 
	  
 	  
 	 Name: 
 	 Theodore M. Wright
 
	  
 	  
 	 Title: 
 	 Vice President and Treasurer
 

	 
 
 
 	 Attest: 
 	 
 /s/ STEPHEN K. COSS
 
	  
 	  
 	 
 
	  
 	  
 	 Stephen K. Coss, Secretary
 

  
 
 

  SCHEDULE A
 Schedule A attached to
and forming a part of the Promissory Note dated December           , 2002 in the principal amount of $50,000,000.00 from the named subsidiaries of Sonic
Automotive, Inc. to Toyota Motor Credit Corporation.
  

	 Date
 	  
 	 Advance
 Amount – 
 Principal

	  
 	 Advance
 Amount – Budgeted
 Interest
 	  
 	 Property
 
	 
 	  
 	 
 	  
 	 
 	  
 	 
 
	  
 	  
 	  
 	  
 	  
 	  
 	  
 	  
 	  
 
	  
 	  
 	 $
 	  
 	  
 	 $
 	  
 	  
 	  
 
	 
 	  
 	  
 	 
 	  
 	  
 	 
 	  
 	 
 
	  
 	  
 	 $
 	  
 	  
 	 $
 	  
 	  
 	  
 
	 
 	  
 	  
 	 
 	  
 	  
 	 
 	  
 	 
 
	  
 	  
 	 $
 	  
 	  
 	 $
 	  
 	  
 	  
 
	 
 	  
 	  
 	 
 	  
 	  
 	 
 	  
 	 
 
	  
 	  
 	 $
 	  
 	  
 	 $
 	  
 	  
 	  
 
	 
 	  
 	  
 	 
 	  
 	  
 	 
 	  
 	 
 
	  
 	  
 	 $
 	  
 	  
 	 $
 	  
 	  
 	  
 
	 
 	  
 	  
 	 
 	  
 	  
 	 
 	  
 	 
 
	  
 	  
 	 $
 	  
 	  
 	 $
 	  
 	  
 	  
 
	 
 	  
 	  
 	 
 	  
 	  
 	 
 	  
 	 
 
	  
 	  
 	 $
 	  
 	  
 	 $
 	  
 	  
 	  
 
	 
 	  
 	  
 	 
 	  
 	  
 	 
 	  
 	 
 
	  
 	  
 	 $
 	  
 	  
 	 $
 	  
 	  
 	  
 
	 
 	  
 	  
 	 
 	  
 	  
 	 
 	  
 	 
 
	  
 	  
 	 $
 	  
 	  
 	 $
 	  
 	  
 	  
 
	 
 	  
 	  
 	 
 	  
 	  
 	 
 	  
 	 
 

  
 
 

  SCHEDULE B
 Schedule B attached to
and forming a part of the Promissory Note dated December          , 2002 in the principal amount of $50,000,000.00 from the named subsidiaries of Sonic
Automotive, Inc. to Toyota Motor Credit Corporation.
  

	 Date
 	  
 	 Amount of Payment
 	  
 	 Advance No.
 	  
 	 Property
 
	 
 	  
 	 
 	  
 	 
 	  
 	 
 
	  
 	  
 	  
 	  
 	  
 	  
 	  
 	  
 
	  
 	  
 	 $
 	  
 	  
 	  
 	  
 	  
 
	 
 	  
 	  
 	 
 	  
 	 
 	  
 	 
 
	  
 	  
 	 $
 	  
 	  
 	  
 	  
 	  
 
	 
 	  
 	  
 	 
 	  
 	 
 	  
 	 
 
	  
 	  
 	 $
 	  
 	  
 	  
 	  
 	  
 
	 
 	  
 	  
 	 
 	  
 	 
 	  
 	 
 
	  
 	  
 	 $
 	  
 	  
 	  
 	  
 	  
 
	 
 	  
 	  
 	 
 	  
 	 
 	  
 	 
 
	  
 	  
 	 $
 	  
 	  
 	  
 	  
 	  
 
	 
 	  
 	  
 	 
 	  
 	 
 	  
 	 
 
	  
 	  
 	 $

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00048-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00048-of-00352.parquet"}]]