Document:

exv10w9

Exhibit
10.9

LEASE AGREEMENT BETWEEN

RIVERSIDE AVENUE PARTNERS, LTD.,

AS LANDLORD, AND

EVERBANK,

AS TENANT

DATED March 26, 2007

 

 

BASIC LEASE INFORMATION

	 	 	 	 	 

	Lease Date:

	 	March 26, 2007.	 	 
	 
	 	 	 	 
	Landlord:	 	RIVERSIDE AVENUE PARTNERS, LTD., A Florida limited partnership.
	 
	 	 	 	 
	Tenant:	 	EVERBANK, a federal savings association organized under the laws of
the United States of America.
	 
	 	 	 	 
	Permitted Use	 	Retail banking offices on 1st floor of the Building.
	 
	 	 	 	 
	Premises

	 	Retail Banking

Space
	 	3,276 rentable square feet on the 1st
floor of the Building known as EverBank Plaza;
street address is 501 Riverside Avenue, Jacksonville, Florida 32202.
	 
	 	 	 	 
	 

	 	Drive-Through
	 	A drive-through banking facility within the
demised premises together with vehicular access through the Building’s
parking garage to the drive-through.
	 
	 	 	 	 
	 	 	The Premises are outlined on the plan attached to the Lease as
Exhibit A . The Land is described on Exhibit B.
	 
	 	 	 	 
	Parking	 	10 total parking spaces in the Parking Garage (see Exhibit G).
	 
	 	 	 	 
	Initial Term:	 	120 months, commencing on the Commencement Date and ending at 5:00
p.m. local time on the last day of the 120th full calendar month following
the Commencement Date, subject to adjustment and earlier termination as
provided in the Lease.
	 
	 	 	 	 
	Renewal Options	 	Tenant has option to renew for three 5-year renewal terms if Tenant
delivers written notice thereof to Landlord no later than 6 months prior to
the commencement of such renewal term.
	 
	 	 	 	 
	Commencement Date	 	The earliest of the date on which: (a) Tenant occupies any portion of
the Premises and begins conducting business therein; (b) the Work in the
Premises is Substantially Completed; or (c) the Work in the Premises would
have been Substantially Completed but for the occurrence of any Tenant
Delay Days.
	 
	 	 	 	 
	Rent	 	Basic Rent, Drive-Through Rent, Tenant’s share of Additional Rent,
and all other sums that Tenant may  owe to Landlord or otherwise be
required to pay under the Lease.

i

 

			
	Basic Rent	 	The monthly Basic Rent shall be the following amounts for the following periods
of time:

	 	 	 	 	 	 	 	 	 	 	 	 	 	 	 	 	 
	 	 	Bank Space Rental	 	Monthly Basic	 	 	 	 	 	Monthly
	Lease Month	 	Rate Per Square Foot	 	Rent	 	Sales Tax	 	Payment*
	1-12
	 	$	25.00	 	 	$	6,825.00	 	 	$	477.75	 	 	$	7,302.75	 
	13-24
	 	$	25.75	 	 	$	7,029.75	 	 	$	492.08	 	 	$	7,521.83	 
	25-36
	 	$	26.52	 	 	$	7,240,64	 	 	$	506.84	 	 	$	7,747.49	 
	37-48
	 	$	27.32	 	 	$	7,457.86	 	 	$	522.05	 	 	$	7,979.91	 
	49-60
	 	$	28.14	 	 	$	7,681.60	 	 	$	537.71	 	 	$	8,219.31	 
	61-72
	 	$	28.98	 	 	$	7,912.05	 	 	$	553.84	 	 	$	8,465.89	 
	73-84
	 	$	29.85	 	 	$	8,149.41	 	 	$	570.46	 	 	$	8,719.87	 
	85-96
	 	$	30.75	 	 	$	8,393.89	 	 	$	587.57	 	 	$	8,981.46	 
	97-108
	 	$	31.67	 	 	$	8,645.71	 	 	$	605.20	 	 	$	9,250.91	 
	109-120
	 	$	32.62	 	 	$	8,905.08	 	 	$	623.36	 	 	$	9,528.43	 

 

			
	*	 	Not including Additional Rent.

			
	Tenant Improvement 

Allowances	 	$15.00 per rentable square foot of office space to be used for the construction of the Premises, space
planning, architectural documents and obtaining permits.

			
	Tenant’s Proportionate 

Share	 	1.6% 

			
	Drive-Through Rent:	 	The monthly rent for the drive-through shall be the following amounts for the
following periods of
time.

	 	 	 	 	 	 	 	 	 	 	 	 	 
	 	 	 	 	 	 	 	 	 	 	Total Monthly
	Lease Month	 	Monthly Rent	 	Sales Tax	 	Payment
	1-12
	 	$	1,500.00	 	 	$	105.00	 	 	$	1,605.00	 
	13-24
	 	$	1,545.00	 	 	$	108.15	 	 	$	1,653.15	 
	25-36
	 	$	1,591.35	 	 	$	111.39	 	 	$	1,702.74	 
	37-48
	 	$	1,639.09	 	 	$	114.74	 	 	$	1,753.83	 
	49-60
	 	$	1,688.26	 	 	$	118.18	 	 	$	1,806.44	 
	61-72
	 	$	1,738.91	 	 	$	121.72	 	 	$	1,860.63	 
	73-84
	 	$	1,791.08	 	 	$	125.38	 	 	$	1,916.45	 
	85-96
	 	$	1,844.81	 	 	$	129.14	 	 	$	1,973.95	 
	97-108
	 	$	1,900,16	 	 	$	133.01	 	 	$	2,033.17	 
	108-120
	 	$	1,957.16	 	 	$	137.00	 	 	$	2,094.16	 

ii

 

	 	 	 	 	 

	Tenant’s Address:*

	 	For all Notices:
	 	With a copy to:
	 

	 	501 Riverside Avenue
	 	501 Riverside Avenue
	 

	 	Jacksonville, Florida 32202
	 	Jacksonville, Florida 32202
	 

	 	Attention: W. Blake Wilson, President
	 	Attention: Thomas A. Hajda, General Counsel
	 

	 	Telephone: (904) 281-6048
	 	Telephone: (904) 332-7604
	 

	 	Telecopy: (904) 281-6145
	 	Telecopy: (904) 470-2797
	 
	 	 	 	 
	Landlord’s Address:

	 	For all Notices:
	 	With a copy to:
	 

	 	806 Riverside Avenue
	 	M.C. Harden III
	 

	 	Jacksonville, FL 32204
	 	P.O. Box 2286
	 

	 	Attention: Paul J. Lunetta
	 	Jacksonville, FL 32203
	 

	 	Telephone: (904) 421-5325
	 	Telephone: (904) 421-5332
	 

	 	Telecopy: (904) 634-1302
	 	Telecopy: (904) 634-1302

 

			
	*	 	Until Tenant has taken possession of the Premises, its address for notices shall be 8100
Nations Way, Jacksonville, FL 32256.

iii

 

The foregoing Basic Lease Information is incorporated into and made a part of the
Lease identified above. If any conflict exists between any Basic Lease Information
and the Lease, then the Lease shall control.

	 	 	 	 	 	 	 	 	 

	LANDLORD:	 	RIVERSIDE AVENUE PARTNERS, LTD.	 	 
	 
	 	 	 	 	 	 	 	 
	 	 	By:	 	RAP Property Management, LLC, as its

General Partner	 	 
	 
	 	 	 	 	 	 	 	 
	 

	 	 	 	By:	 	 	 	 
	 

	 	 	 	Name:
	 	 

	 	 
	 

	 	 	 	Title:
	 	 

	 	 
	 

	 	 	 	 	 	 

	 	 

	 	 	 	 	 	 	 

	TENANT:	 	EVERBANK	 	 
	 
	 	 	 	 	 	 
	 

	 	By:

Name:
	 	/s/ W. Blake Wilson
 

W. Blake Wilson
	 	 
	 

	 	Title:
	 	President	 	 

iv

 

TABLE OF CONTENTS

	 	 	 	 	 
	 	 	Page No.
	1. DEFINITIONS
	 	 	1	 
	 
	 	 	 	 
	2. LEASE GRANT
	 	 	6	 
	 
	 	 	 	 
	3. TENDER OF POSSESSION
	 	 	6	 
	 
	 	 	 	 
	4. RENT
	 	 	6	 
	 
	 	 	 	 
	5. DELINQUENT RENT PAYMENT
	 	 	7	 
	 
	 	 	 	 
	6. PARTIES’ OBLIGATIONS
	 	 	7	 
	 
	 	 	 	 
	7. IMPROVEMENTS; ALTERATIONS; REPAIRS; MAINTENANCE
	 	 	8	 
	 
	 	 	 	 
	8. TENANT’S USE OF PREMISES
	 	 	10	 
	 
	 	 	 	 
	9. ASSIGNMENT AND SUBLETTING
	 	 	11	 
	 
	 	 	 	 
	10. INSURANCE
	 	 	13	 
	 
	 	 	 	 
	11. INDEMNIFICATION
	 	 	14	 
	 
	 	 	 	 
	12. SUBORDINATION; ATTORNMENT; NOTICE TO LANDLORD’S MORTGAGEE
	 	 	17	 
	 
	 	 	 	 
	13. RULES AND REGULATIONS
	 	 	18	 
	 
	 	 	 	 
	14. CONDEMNATION
	 	 	18	 
	 
	 	 	 	 
	15. FIRE OR OTHER CASUALTY
	 	 	19	 
	 
	 	 	 	 
	16. PERSONAL PROPERTY TAXES
	 	 	20	 
	 
	 	 	 	 
	17. EVENTS OF DEFAULT
	 	 	20	 
	 
	 	 	 	 
	18. REMEDIES
	 	 	21	 
	 
	 	 	 	 
	19. PAYMENTS BY PARTIES; NON-WAIVER; CUMULATIVE REMEDIES
	 	 	22	 
	 
	 	 	 	 
	20. SURRENDER OF PREMISES
	 	 	22	 
	 
	 	 	 	 
	21. HOLDING OVER
	 	 	23	 
	 
	 	 	 	 
	22. CERTAIN RIGHTS RESERVED BY LANDLORD
	 	 	23	 
	 
	 	 	 	 
	23. MISCELLANEOUS
	 	 	23	 
	 
	 	 	 	 
	24. REPRESENTATIONS AND WARRANTIES
	 	 	28	 
	 
	 	 	 	 
	EXHIBIT A OUTLINE OF PREMISES
	 	 	A-1	 
	 
	 	 	 	 
	EXHIBIT B DESCRIPTION OF LAND
	 	 	B-1	 
	 
	 	 	 	 
	EXHIBIT C RULES AND REGULATIONS
	 	 	C-1	 
	 
	 	 	 	 
	EXHIBIT D WORK LETTER
	 	 	D-1	 
	 
	 	 	 	 
	EXHIBIT E CONFIRMATION OF COMMENCEMENT DATE
	 	 	E-1	 
	 
	 	 	 	 
	EXHIBIT F FORM OF TENANT ESTOPPEL CERTIFICATE
	 	 	F-1	 
	 
	 	 	 	 
	EXHIBIT G PARKING
	 	 	G-1	 
	 
	 	 	 	 
	EXHIBIT H RENEWAL OPTION
	 	 	H-1	 
	 
	 	 	 	 
	EXHIBIT I INTENTIONALLY DELETED
	 	 	I-1	 
	 
	 	 	 	 
	EXHIBIT J SIGNAGE
	 	 	J-1	 
	 
	 	 	 	 
	EXHIBIT K OPERATING COSTS
	 	 	K-1	 

i

 

LEASE

          This Lease Agreement (this “Lease”) is entered into as of this 26th day of
March, 2007, by and
between RIVERSIDE AVENUE PARTNERS, LTD., a Florida limited partnership,
(“Landlord”), and EVERBANK, a federal savings bank organized under the laws of the United
States of America (“Tenant”).

     1. Definitions. The capitalized terms used in this Lease have the
meanings set forth below.

          “Action” means any action, arbitration, cause of action, Claim, complaint,
dispute, criminal prosecution, governmental or other examination or investigation, hearing,
administrative or other proceeding relating to or affecting a Party, its business, its assets
(including contracts relating thereto), or the Services hereunder.

          “Additional Rent” means Tenant’s Proportionate Share of Operating Costs.

          “Additional Rental Losses” means any rental payments and costs that: (a) are paid
by Tenant to any Person between the Delivery Date and the date following the Final Delivery
Date on which Landlord tenders possession of the Premises to Tenant in the condition required
by this Lease; and (b) exceed the Rent that Tenant would have paid to Landlord for the period
described in subparagraph (a) of this definition.

          “Additional Rent Support Documentation” means: (a) all information, documents and
materials supporting Landlord’s estimate of any Additional Rent; and (b) all calculations and
other methods used by Landlord to estimate any Additional Rent.

          “Affiliate” means, with respect to a Party, any Person at any time Controlling,
Controlled by or under common Control with such Party.

          “Applicable Law” means all applicable: (a) federal, state and local legal and
regulatory requirements, including statutes, rules, regulations, ordinances and judicial
interpretations thereof that are binding upon a Party; (b) requirements and guidelines of each
governmental agency, board, commission, instrumentality, self regulatory organization and
other such body or officer having jurisdiction over a Party; (c) judicial and administrative
judgments, orders, stipulations, awards, writs and injunctions; and (d) all restrictive
covenants affecting the Project.

          “Basic Lease Information” the form of Basic Lease Information attached hereto and
executed by the Parties contemporaneously herewith.

          “Basic Rent” means the monthly base rental payments that Tenant is required to pay
Landlord during specified time periods throughout the Term, as described in the Basic Lease
Information.

          “Building Holiday” means New Year’s Day, Memorial Day, Independence Day, Labor
Day, Thanksgiving Day and Christmas Day.

          “Business Day” means any day other than a Saturday, a Sunday, or a day on which
banks in Jacksonville, Florida are authorized or required by Applicable Law to close.

          “Building” means office building commonly known as EverBank Plaza and
located at 501 Riverside
Avenue, Jacksonville, Florida 32202.

          “Building’s Structure” means the Building’s exterior walls, roof, elevator
shafts, footings, foundations, structural portions of load-bearing walls, structural floors
and subfloors, and structural columns and beams.

          “Building’s Systems” means the Building’s HVAC, life-safety, plumbing,
electrical, and mechanical systems.

          “Casualty” means a fire or other casualty that damages the Premises.

          “Claim” means any claim, demand, investigation, action, and legal action or
proceeding.

          “Commencement Date” means the earliest of the date on which: (a) Tenant
occupies any portion of the

1

 

Premises and begins conducting business therein; (b) the Work in the Premises is Substantially
Completed; or (c) the Work in the Premises would have been Substantially Completed but for the
occurrence of any Tenant Delay Days.

     “Confidential Information” means any proprietary and confidential information of a
Party or any of its Affiliates, provided, produced or disclosed by or on behalf of the Disclosing
Party to the Receiving Party or otherwise obtained by the Receiving Party, in written, electronic,
oral or other form, whether tangible or intangible, including, but not limited to: (a) financial
information, marketing plans, and personnel records; (b) technical and non-technical data,
including, but not limited to, fee schedules, forms, information, business and management methods,
trade secrets, compilation and analysis of financial information and data to prepare and submit
bids and proposals to third Persons; (c) other proprietary or confidential information; (d)
proprietary computer software, management information and information systems; (e) customer
information; (f) the terms and provisions of this Lease and any transaction or document executed by
the Parties pursuant to this Lease; provided, however, that Confidential Information shall
not include any information that is: (i) publicly available or later becomes publicly available
other than through a breach of this Lease, (ii) rightfully in the possession of the Receiving Party
or its employees, attorneys, accountants, agents or other Representatives without obligation of
confidence prior to disclosure by the other Party, (iii) subsequently lawfully obtained by the
Receiving Party or its employees, agents or Representatives from a third Person that is not under
any obligations of confidentiality, (iv) independently developed by the Receiving Party or its
employees, agents or Representatives, without use of or reference to the Confidential Information
of the Disclosing Party; or (v) legally required to be disclosed by the Receiving Party;
provided further that these exclusions shall not apply to Customer Information, which in
all instances shall be treated as Confidential Information. As to such disclosures required by
Applicable Law, the Receiving Party shall provide the Disclosing Party with reasonable notice prior
to such disclosure to the extent permissible under the order requiring disclosure.

          “Control, Controlling, or Controlled” means the legal, beneficial or
equitable ownership, directly or indirectly, of more than fifty percent of the aggregate of all
voting equity interests in a business entity.

          “Damage Notice” means the written notice provided by Landlord to Tenant following a
Casualty setting forth a good faith estimate of the time needed to repair the damage caused by
such Casualty.

          “Default Rate” means the rate of interest charged with respect to Tenant’s past due
payments hereunder, which rate shall be the lesser of: (a) eighteen percent (18%) per annum; or
(b) the maximum lawful rate of interest.

          “Delivery Date” means June 1, 2007, which is the date on which Landlord estimates
that possession of the Premises shall be tendered to Tenant in the condition required hereby.

          “Disabilities Acts” means Title III of the Americans With Disabilities Act of 1990,
any state laws governing handicapped access or architectural barriers, and all rules, regulations,
and guidelines promulgated under such laws, as amended from time to time.

          “Disclosing Party” means a Party that discloses Confidential Information to the
other Party.

          “Dispute” means any dispute, controversy, Claim or disagreement between the Parties
arising from, relating to or in connection with this Lease or the relationship of the Parties
hereunder, including, but not limited to: (a) payment of rent and fees hereunder; (b)
interpretation of the meaning of, performing obligations under or enjoying rights under this
Lease; (c) indemnification obligations hereunder; and/or (d) Claims based on contract, tort,
common law, equity, statute, regulation, order or otherwise.

          “Drive-Through Rent” means the monthly drive-through rental payments that Tenant is
required to pay Landlord during specified time periods throughout the Term, as described in the
Basic Lease Information.

          “Final Delivery Date” means the date that is 90 days after the Delivery Date.

          “GAAP” means generally accepted accounting principles, consistently applied during
the periods involved.

2

 

          “Hazardous Materials” means any substance, material or waste that is now or
hereafter classified or considered to be hazardous, toxic, or dangerous under Applicable Law
relating to pollution or the protection or regulation of human health, natural resources or the
environment, or poses or threatens to pose a hazard to the health or safety of persons on the
Premises or in the Project.

          “HVAC” means heated and refrigerated air conditioning.

          “Indemnification Claim” means a Claim for indemnification hereunder.

          “Indemnified Person” means each Person who has the right to indemnification
hereunder.

          “Indemnifying Person” means each Person who is obligated to indemnify another Person
hereunder.

          “Initial Liability Insurance Amount” means amounts set forth in Section 10.

          “Land” means the land on which the Building is located, as described further in
Exhibit B.

          “Landlord” shall have the meaning set forth in the Preamble hereto.

          “Landlord Contractors” means contractors, subcontractors and/or materialmen who: (a)
are selected by Landlord; and (b) perform services in connection with the Premises and/or
Building.

          “Landlord Event of Default” means the event of default by Landlord, as set forth in
Section 17(b).

          “Landlord’s Mortgagee” means any mortgagee under any of Landlord’s Mortgages,
beneficiary under any of Landlord’s deeds of trust or lessor under any of Landlord’s Primary
Leases.

          “Lease” shall have the meaning set forth in the Preamble hereto.

          “Lease Month” means each calendar month during the Term (and if the Commencement Date
does not occur on the first day of a calendar month, the period from the Commencement Date to the
first day of the next calendar month shall be included in the first Lease Month for purposes of
determining the duration of the Term and the monthly Basic Rent rate applicable for such partial
month).

          “Liability” means any direct or indirect, primary or secondary, liability,
indebtedness, obligation, responsibility, penalty, cost or expense (including costs of
investigation, collection and defense), Claim, deficiency, guaranty or endorsement of or by any
Person of any type, whether accrued, absolute or contingent, liquidated or unliquidated, choate or
inchoate, matured or unmatured, secured or unsecured, or otherwise.

          “Loss” means any direct or indirect demand, Claim, payment, obligation, action or
cause of action, assessment, loss, Liability, cost, damage, deficiency or expense, including, but
not limited to: (a) penalties, interest on any amount payable to a third Person as a result of
the foregoing, and any reasonable attorneys’ fees, accountants’ fees, expert witness fees and
related fees and court costs legal or other expense reasonably incurred in connection with
investigating, defending, or responding to same.

          “Mortgage” means a deed of trust, mortgage or other such security instrument.

          “Operating Costs” shall mean those expenses and disbursements that Landlord incurs in
connection with the ownership, operation, and maintenance of the Project, as more specifically set
forth on Exhibit K, attached hereto.

          “Operating Costs Statement” means a written statement provided by Landlord to Tenant
each year during the Term hereof commencing April 1, 2008, setting forth the Operating Costs for
the previous calendar year, as adjusted in the manner set forth herein.

          “Parking Garage” means the parking garage adjacent to the Building, as more
particularly described in Exhibit G.

3

 

          “Parties” means EverBank and Landlord.

          “Party” means EverBank or Landlord, as the context shall require.

          “Permitted Transfer” means Tenant’s Transfer of all or part of Tenant’s interest in
this Lease and/or the Premises to a Permitted Transferee without Landlord’s prior consent.

          “Permitted Transferee” means a Person identified in Section 9(h) to which Tenant may
engage in a Permitted Transfer without Landlord’s prior consent.

          “Permitted Use” means Tenant’s permitted use of the Premises, which shall be a
retail banking.

          “Person” mean an individual, corporation, limited liability company, partnership,
joint venture, bank, savings association, trust or unincorporated organization, or a federal,
state, city, municipal or foreign government or an agency or political subdivision thereof.

          “Premises” means a portion of the 1st Floor, containing 3,276 rentable
square feet in the Building, together with the bank drive-through facility.

          “Primary Lease” means a ground lease, master lease, or primary lease.

          “Project” means the Building, the Land and the driveways, parking facilities, and
similar improvements and easements associated with the foregoing or the operation thereof.

          “Rent” means the Basic Rent, Tenant’s share of Additional Rent, and all other sums
that Tenant may owe to Landlord or otherwise be required to pay hereunder.

          “Repair Period” means 120 days after the date of the related Casualty.

          “Representative” means any investment banker, financial advisor, attorney,
accountant, consultant or other Representative of a Person.

          “Sanitary Services” means garbage collection and janitorial services.

          “Space Plans” means the Tenant’s space plans depicting improvements to be installed
in the Premises (Exhibit D).

          “Special Deposit Account” means a deposit account: (a) established by Landlord at an
office of a federally insured depository institution situated in Jacksonville, Florida; (b)
segregated from Landlord’s other deposit accounts and/or funds; (c) established as a fiduciary
account for the benefit of Tenant and identifying Tenant as the beneficial owner thereof; (d) into
which shall be deposited funds consisting solely of any security or advance rental deposit made by
Tenant hereunder and any additional rent or advance rent that Tenant may pay hereunder for more
than the current month to Landlord or any successor thereto; (e) the funds of which shall be
accessible by Tenant in the event Landlord’s Mortgagee shall succeed to Landlord’s interest
hereunder; (f) with respect to which Landlord shall not withdraw any portion of the funds therein
unless such portion represents rents, security or rental deposits that are currently due and
payable hereunder.

          “Substantial Completion” and “Substantially Completed” mean the Work in the
Premises is substantially completed (as reasonably determined by Landlord) in substantial
accordance with the Working Drawings. Substantial Completion shall have occurred even though minor
details of construction, decoration, landscaping and mechanical adjustments remain to be completed
by Landlord.

          “Taking” means the taking of all or part of the Building or Premises by right of
eminent domain or conveyance in lieu thereof.

          “Tangible Net Worth” means the excess of total assets over total liabilities, in each
case as determined in accordance with GAAP, consistently applied, excluding, however, from
the determination of total assets all assets

4

 

that would be classified as intangible assets under GAAP, including goodwill, licenses, patents,
trademarks, trade names, copyrights, and franchises.

          “Taxes” means any: (a) federal, state, county or municipal taxes, assessments and
governmental charges or fees, whether by existing taxing districts or authorities or by taxing
districts or authorities subsequently created; (b) other taxes and assessments, including
non-governmental assessments for common charges under restrictive covenants or other private
agreements that are not treated as part of Operating Costs, now or hereafter attributable to the
Project or its operation, excluding, however, penalties and interest thereon and federal
and state taxes on income (if the present method of taxation changes so that in lieu of or in
addition to the whole or any part of any Taxes, there is levied on Landlord a capital tax directly
on the rents received therefrom or a franchise tax, assessment, or charge based, in whole or in
part, upon such rents for the Project, then all such taxes, assessments, or charges, or the part
thereof so based, shall be deemed to be included within the term “Taxes” for purposes hereof); and
(c) costs of consultants retained in an effort to lower taxes and all costs incurred in disputing
any taxes or in seeking to lower the tax valuation of the Project.

          “Telecommunications Services” means telecommunications systems, including voice,
video, data, Internet, and any other services provided over wire, fiber optic, microwave,
wireless, and any other transmission systems.

          “Tenant” shall have the meaning set forth in the Preamble hereto.

          “Tenant Contractors” means contractors, subcontractors and/or materialmen who: (a)
are selected by a Tenant Party; and (b) perform services in connection with the Premises and/or
Building.

          “Tenant Delay Day” means each day of delay in the performance of the Work that occurs
because of any: (a) failure by Tenant to deliver to Landlord within any time period specified
herein any information or documentation required hereunder, including the Space Plans, Working
Drawings (whether preliminary, interim revisions or final), pricing estimates and construction
bids; (b) change by Tenant to the Space Plans or Working Drawings, other than as permitted by
Landlord herein; (c) failure by Tenant to attend any meeting with Landlord, the architect, design
professional or other contractor, or their respective employees or representatives, as shall be
required or scheduled hereunder and necessary in connection with the preparation or completion of
any construction documents, such as the Space Plans, Working Drawings, or in connection with the
performance of the Work; (d) specification by Tenant of materials or installations in addition to
or other than Landlord’s standard finish-out materials that Landlord has identified as potentially
causing delays in the completion of the Work; or (e) other delay in the completion of the Work
caused directly by Tenant and not otherwise excused hereunder.

          “Tenant Event of Default” means the event of default by Tenant, as set forth in
Section 17(a).

          “Tenant Party” means any of the following Persons: (a) Tenant;(b) any assignees
claiming by, through or under Tenant; (c) any subtenants claiming by, through or under Tenant; and
(d) any of their respective agents, contractors, employees, licensees, guests and invitees.

          “Tenant’s Off-Premises Equipment” means any of Tenant’s equipment or other property
that may be located on or about the Project, other than inside the Premises, including Tenant’s
drive-through customary banking equipment located within the Parking Garage.

          “Tenant’s Proportionate Share” means the percentage identified in the Basic Lease
Information that was calculated by dividing: (a) the rentable square feet in the Premises; by (b)
the 207,022 rentable square feet in the Building. Landlord and Tenant stipulate to the percentage
set forth in the Basic Lease Information.

          “Term” means the term of this Lease.

          “Third Person Claim” means any Action that is instituted against an Indemnified
Person by a Person other than an Indemnifying Person and which, if prosecuted successfully, would
result in Losses for which such Indemnified Person is entitled to indemnification under Section
11.

          “Transfer” means Tenant’s: (a) assignment, transfer or encumbrance of this Lease or
any estate or interest herein; (b) subletting of any portion of the Premises; (c) granting to
another Person any license, concession or other

5

 

right of occupancy of any portion of the Premises; and/or (d) permitting another Person to use the
Premises. Notwithstanding the foregoing, “Transfer” shall not include Tenant’s permitting: (i)
another Person to become Tenant hereunder by merger, consolidation, or other reorganization; or
(ii) the transfer of an ownership interest in Tenant so as to result in a change in the current
Control of Tenant.

          “UCC” means the Uniform Commercial Code of the State of Florida.

          “Utilities” means water, sewer, electricity and natural gas.

          “Work” means all improvements to be constructed by Landlord in accordance with and as
indicated on the Working Drawings (Exhibit D).

          “Working Drawings” means the Approved Construction Drawings (Exhibit D).

     2. Lease Grant. Subject to the terms of this Lease, Landlord leases the
Premises to Tenant and Tenant leases the Premises from Landlord, together with the parking spaces
in the Parking Garage as set forth at Exhibit G to this Lease.

     3. 
Tender of Possession.

          (a) Delivery Date. Landlord and Tenant presently anticipate that possession of the Premises
and parking will be tendered to Tenant in the condition required by this Lease on the Delivery
Date. If Landlord is unable to tender possession of the Premises in such condition to Tenant by
the Delivery Date but before the Final Delivery Date: (i) the validity of this Lease shall not be
affected or impaired thereby; (ii) Landlord shall not be in default hereunder or be liable for
Losses therefor, and (iii) Tenant shall accept possession of the Premises when Landlord tenders
possession thereof to Tenant.

          (b) Failure to Deliver by Final Delivery Date. If Landlord is unable to tender possession of
the Premises in the condition required by this Lease to Tenant by the Final Delivery Date. Tenant
may: (i) terminate this Lease immediately; or (ii) accept possession and occupy the Premises after
the Final Delivery Date with a reduction in the first six (6) months’ Base Rent in such amount as
necessary to compensate Tenant for any Additional Rental Losses.

          (c) Accepting Conditions of Premises. By occupying the Premises, Tenant shall be deemed to
accept the Premises in their condition as of the date of such occupancy, subject to the
performance of any punch-list items that remain to be performed by Landlord. Prior to occupying
the Premises, Tenant shall execute and deliver to Landlord a letter substantially in the form of
Exhibit E hereto. Except as set forth in Section 3(b), the Parties’ failure to execute
such letter shall not defer the Commencement Date or otherwise invalidate this Lease.

     4. 
Rent.

          (a) Payment. Except as otherwise expressly provided herein, Tenant shall timely pay Rent to
Landlord, without notice, demand, deduction or set off, by good and sufficient check drawn on a
federally insured depository institution at Landlord’s address identified in the Basic Lease
Information or as otherwise specified in writing by Landlord and shall be accompanied by all
applicable state and local sales or use taxes. The obligations of Tenant to pay Rent and the
obligations of Landlord under this Lease are independent obligations. Basic Rent, adjusted as
herein provided, shall be payable monthly in advance. The first monthly installment of Basic Rent
shall be payable on the Commencement Date; thereafter, Basic Rent shall be payable on the first day
of each month beginning on the first day of the first full calendar month of the Term. The monthly
Basic Rent for any partial month at the beginning of the Term shall equal the product of 1/365 of
the annual Basic Rent in effect during the partial month and the number of days in the partial
month and shall be due on the Commencement Date. Payments of Basic Rent for any fractional calendar
month at the end of the Term shall be similarly prorated. Tenant shall pay Additional Rent and
Drive-Through Rent at the same time and in the same manner as Basic Rent. Payments of Additional
Rent and Drive-Through Rent shall be accompanied by all applicable state and local sales taxes.

          (b) Additional Rent. Tenant shall pay Additional Rent, if any, to Landlord. Landlord may make
a good faith estimate of the Additional Rent to be due by Tenant for any calendar year or part
thereof during the Term. Promptly thereafter, Landlord shall provide the Additional Rent Support
Documentation to Tenant. During each

6

 

calendar year or partial calendar year during the Term, Tenant shall pay to Landlord, in advance
concurrently with each monthly installment of Basic Rent, an amount equal to the estimated
Additional Rent for such calendar year or part thereof divided by the number of months therein.
From time to time, Landlord may estimate and re-estimate the Additional Rent to be due by Tenant
and promptly deliver to Tenant the Additional Rent Support Documentation relating thereto.
Thereafter, the monthly installments of Additional Rent payable by Tenant shall be appropriately
adjusted in accordance with the estimations so that, by the end of the calendar year in question,
Tenant shall have paid all of the Additional Rent as estimated by Landlord. Any amounts paid based
on such an estimate shall be subject to adjustment provided herein when actual Operating Costs are
available for each calendar year.

          (c) Drive-Through Rent. Tenant shall pay Drive-Through Rent to Landlord during each calendar
year or partial calendar year during the Term in advance concurrently with each monthly installment
of Basic Rent. The monthly Drive-Through Rent for any partial month at the beginning of the Term
shall equal the product of 1/365 of the annual Drive-Through Rent in effect during the partial
month and the number of days in the partial month and shall be due on the Commencement Date.
Payments of Drive-Through Rent for any fractional calendar month at the end of the Term shall be
similarly prorated. Payments of Drive-Through Rent shall be accompanied by all applicable state and
local sales or use taxes.

          (d) Waiver of Protest of Appraised Value. For property tax purposes, Tenant waives all rights
to protest or appeal the appraised value of the Premises, as well as the Project, and all rights
to receive notices of reappraisement.

          (e) Operating Cost Statement. Landlord shall furnish an Operating Cost Statement to Tenant on
April 1 of each calendar year during the Term, commencing in calendar year 2008, or as soon
thereafter as practicable. If Tenant’s estimated payments of Operating Costs under Section 4(b)
for the previous year covered by the Operating Costs Statement are: (i) greater than Tenant’s
Proportionate Share of such items as indicated in the Operating Costs Statement, Landlord shall
promptly reimburse Tenant for such excess, or (ii) less than Tenant’s Proportionate Share of such
items as indicated in the Operating Costs Statement, Tenant shall promptly pay Landlord such
deficiency.

     5. Delinquent Rent Payment. All past due payments required of Tenant
hereunder shall bear interest from the date due until paid at the Default Rate.

     6. 
Parties’ Obligations.

          (a) General Services.

          (i) Landlord shall furnish to Tenant: (a) water at those points of supply provided for
general use of tenants of the Building; (b) HVAC, as appropriate, at such temperatures and in such
amounts as are standard for comparable buildings in the vicinity of the Building; (c) Sanitary
Services to those areas of the Building, other than the Premises, the use of which is shared by
all tenants on Business Days; (d) such exterior window washing as may from time to time be
reasonably required; and (e) Building security service. Landlord shall maintain the common areas
of the Building in reasonably good order and condition, except for damage caused by a Tenant
Party.

          (ii) Tenant shall be responsible for obtaining the following services as they relate
exclusively to the Premises: (a) Sanitary. Services; (b) electric service; (c) pest control; and
(d) security services. Landlord shall have the right to designate vendors to provide Sanitary
Services to the Premises, provided the cost of such services is competitive in the vicinity of the
Building.

          (b) HVAC Services During Non-Business Hours. Tenant shall e-mail or hand-deliver a notice to
Landlord prior to each occasion when Tenant desires to receive after hours HVAC services: (i)
after 8:00 p.m. and before 7:00 a.m. on a Business Day; (ii) at any time after 1:00 p.m. and
before 8:00 a.m. on a Saturday that is not a Building Holiday; or (iii) on a Sunday or Building
Holiday. Landlord shall: (A) provide such services to Tenant as soon as reasonably practical after
Landlord receives such notice from Tenant; (B) charge Tenant for such HVAC services in an amount
equal to $30.00 per hour or part thereof; and (C) provide Tenant with a written invoice for such
HVAC services,. Tenant shall pay such fees to Landlord within thirty (30) days after Landlord has
delivered such invoice to Tenant, provided that no such fee is the subject of a good faith
Dispute. If Tenant Disputes any item in any such invoice, Tenant shall pay the undisputed items in
such invoice and negotiate in good faith with Landlord with respect to any such costs in Dispute.

7

 

          (c) Utility Use.

               (i) Electrical Services. Tenant shall arrange for a separate account with JEA for its
electrical usage in the Premises. Landlord shall only be responsible for providing electric and
telephone lines to the core of the Building, at which point Tenant shall make its connection and
assume responsibility.

               (ii) Tenant’s Installation of Non-Standard Electrical Equipment. Tenant shall not
install any electrical equipment requiring: (A) special wiring or voltage in excess of 110 volts
unless approved in advance by Landlord, which approval shall not be unreasonably withheld; or (B)
voltage in excess of Building capacity unless approved in advance by Landlord, which approval may
be withheld in Landlord’s sole discretion.

               (iii) Installation of Risers or Wiring to Meet Tenant Needs. The use of electricity
in the Premises shall not exceed the capacity of existing feeders and risers to or wiring in the
Premises. Any risers or wiring required to meet Tenant’s excess electrical requirements shall,
upon Tenant’s written request, be installed by Landlord, at Tenant’s cost, if, in Landlord’s
judgment, the same are necessary and shall not cause permanent damage to the Building or the
Premises, cause or create a dangerous or hazardous condition, entail excessive or unreasonable
alterations, repairs, or expenses, or interfere with or disturb other tenants of the Building.

          (d) Failure of Services Preventing Occupancy.

               (i) Restoration of Services. Landlord shall use its best commercially reasonable
efforts to restore any service required of Landlord that becomes unavailable. Except as provided
below, such unavailability shall not render Landlord liable for any Losses caused thereby, be a
constructive eviction of Tenant, constitute a breach of any implied warranty, or entitle Tenant to
any abatement of Tenant’s obligations hereunder.

               (ii) Abatement. If Tenant is prevented from using the Premises because of the
unavailability of any such service or for any other reason not caused by a Tenant Party for: (A) a
period of seven (7) consecutive days following Landlord’s receipt from Tenant of a written notice
of such unavailability, Tenant shall receive a complete abatement of Rent for each consecutive day
after such 7-day period that Tenant is so prevented from using the Premises; or (B) ten (10) days
within any thirty (30) day period, Tenant shall receive a complete abatement of Rent for each such
day within such thirty (30) day period that Tenant is so prevented from using the Premises.

               (iii) Constructive Eviction; Termination of Lease. Tenant may, in its sole
discretion, terminate this Lease immediately and without penalty or other cost if Tenant is
prevented from using the Premises because of the unavailability of any such service or for any
other reason not caused by a Tenant Party for a period of thirty (30) consecutive days.

          (e) Drive-through. Tenant shall be responsible for the installation and maintenance of any
and all equipment, including without limitation any of Tenant’s Off-Premises Equipment, associated
with the drive through banking facilities.

          (f) Bank Security. Notwithstanding Landlord’s obligation to secure the Building, Tenant shall
be responsible for securing both the Premises and any equipment associated with the drive-through
located in the Parking Garage.

     7. Improvements; Alterations; Repairs; Maintenance.

          (a) Landlord’s Improvements and Alterations. Landlord shall complete improvements to the
Premises in accordance with the Working Drawings and any written plans and specifications mutually
acceptable to the Parties and approved by Landlord under the Work Letter.

          (b) Tenant’s Improvements and Alterations. Tenant shall:

               (i) make each alteration or physical addition in or to the Premises only after receiving
Landlord’s prior written consent, which consent shall not be unreasonably withheld or delayed;
provided, however, that Landlord may withhold its consent to any alteration or addition that would
adversely affect the (A) Building’s Structure or Building’s Systems, including the Building’s
restrooms or mechanical rooms); (B) exterior appearance

8

 

of the Building; (C) appearance of the Building’s common areas or elevator lobby areas; or (D)
provision of services to other tenants of the Building;

               (ii) not paint or install lighting or decorations, signs, window or door lettering or
advertising media of any type visible from the exterior of the Premises;

               (iii) construct maintain and use all alterations, additions and improvements at Tenant’s risk
and expense, in accordance with Applicable Laws; and

               (iv) not deem Landlord’s consent to or approval of any alterations, additions or improvements
or the plans therefor as Landlord’s representation, warranty or acceptance that such alterations,
additions or improvements comply with sound architectural and/or engineering practices or with all
Applicable Laws.

          (c) Tenant’s Repairs and Maintenance. Tenant shall: (i) maintain the Premises in a clean,
safe and operable condition; (ii) not permit or allow to remain any waste or damage to any portion
of the Premises; (iii) at Tenant’s sole expense, shall repair, replace and maintain in good
condition and in accordance with Applicable Laws and the equipment manufacturer’s suggested
service programs, all portions of the Premises, Tenant’s Off-Premises Equipment and all areas,
improvements and systems exclusively serving the Premises; (iv) repair or replace, subject to
Landlord’s direction and supervision, any damage to the Building caused by a Tenant Party.

          (d) Landlord’s Repairs and Maintenance. Landlord may, at Tenant’s expense: (i) repair or
replace damages to the Premises caused by a Tenant Party if Tenant fails to make any such repair
within thirty (30) days after the occurrence of such damage; and (ii) repair any damages caused by
a Tenant Party to the Building outside of the Premises. Landlord shall provide to Tenant a written
invoice setting forth the amount of Landlord’s actual cost of making any such repair or
replacement, including all information and documentation necessary to support the validity and
accuracy of such costs. Tenant shall pay such costs to Landlord within thirty (30) days after
Landlord has such delivered such invoice to Tenant, provided that no such cost is the subject of a
good faith Dispute. If Tenant Disputes any item in any such invoice, Tenant shall pay the
undisputed items in such invoice and negotiate in good faith with Landlord with respect to any such
costs in Dispute.

          (e) Performance of Improvements, Alterations Repairs and Maintenance.

               (i) In General. All improvements, alterations, repairs or maintenance that Tenant is
required to make under this Section 7 shall be performed only by a contractor approved by Landlord
(“Tenant Contractor”).

               (ii) Performance by Tenant Contractors. Tenant shall: (A) obtain Landlord’s prior
written consent before any Tenant Contractor commences any such services; (B) obtain the written
approval of the Building’s engineer of record before any Tenant Contractor provides any services
that may affect the Building’s Structure or the Building’s Systems; (C) provide Landlord with the
name, mailing address and telephone number of each such approved Tenant Contractor; (D) cause each
Tenant Contractor to procure and maintain insurance coverage naming Landlord, Landlord’s property
management company and Landlord’s asset management company as additional insureds against such
risks, in such amounts and with such companies as Landlord may reasonably require; and (E) cause
each Tenant Contractor to perform all improvements, alterations, repairs or maintenance to the
Premises and/or the Building in accordance with Applicable Laws and in a good and workmanlike
manner so as not to damage the Building, including the Premises, the Building’s Structure and the
Building’s Systems. Subject to Applicable Law, Landlord may post on and about the Premises notices
of non-responsibility with respect to any improvement, alteration, repair or maintenance conducted
by a Tenant Contractor.

               (iii) Performance of Work Performed by Landlord Contractors. Landlord shall: (A)
cause each Landlord employee or Landlord Contractor to perform all improvements, alterations,
repairs or maintenance to the Premises and/or the Building in accordance with Applicable Laws and
in a good and workmanlike manner so as not to damage the Building, including the Premises, the
Building’s Structure and the Building’s Systems; (B) obtain the written approval of the Building’s
engineer of record before any Landlord Contractor provides any services that may affect the
Building’s Structure or the Building’s Systems; (C) cause each Landlord Contractor to procure and
maintain insurance coverage naming Landlord, Landlord’s property management company and Landlord’s
asset management company as additional insureds against such risks, in such amounts and with such
companies as shall be commercially reasonable and consistent with commercial practices by
landlords in northeast Florida; and (D)

9

 

cause all improvements, alterations, repairs or maintenance affecting the Building’s roof to be
performed by a qualified roofing contractor in a manner that shall not adversely affect the
integrity thereof or void or reduce the warranty thereon.

          (f) Mechanic’s Liens.

               (i) In General.

                    (A) Tenant’s Authorization of Work. Tenant shall: (I) be deemed to have authorized
and ordered all work performed, materials furnished and obligations performed by a Tenant
Contractor and incurred by or at the request of a Tenant Party; (II) not permit any mechanic’s
liens to be filed against the Premises or the Project in connection therewith; and (III) deliver
to Landlord final lien waivers from all Tenant Contractors after completion of any such work by
such Persons.

                    (B) Landlord’s Authorization of Work. Landlord shall: (I) be deemed to have
authorized and ordered all work performed, materials furnished and obligations performed by a
Landlord Contractor and incurred by or at the request of Landlord or any of its agents or
Representatives; (II) not permit any mechanic’s liens to be filed against the Premises, Building
or the Project in connection therewith; and (III) deliver to Tenant final lien waivers from all
Landlord Contractors after completion of any such work by such Persons.

               (ii) Tenant’s Removal of Mechanics Liens. With respect to any mechanics lien filed
against the Premises or the Project in connection with the services described in Section 7(e)(ii),
Tenant shall: (A) pay the amount of such lien and cause such lien to be released of record; or (B)
diligently contest such lien and deliver to Landlord a bond or other security reasonably
satisfactory to Landlord. Tenant shall take such action within: (I) ten (10) days after Tenant’s
receipt of Landlord’s written notice of the filing of such lien; or (II) such earlier time period
as may be necessary to prevent the forfeiture of the Premises, the Project or any interest of
Landlord therein or the imposition of a civil or criminal fine with respect thereto. Landlord may
pay any such lien claim if Tenant fails to perform its obligations under in Section 7(e)(ii).
Landlord shall provide to Tenant a written invoice of any amounts so paid by Landlord, including
with related expenses and all information and documentation necessary to support the validity and
accuracy of all such amounts paid and expenses incurred. Tenant shall pay such fees to Landlord
within ten (10) days after Landlord has delivered such invoice to Tenant, provided that no such
amount is the subject of a good faith Dispute. If Tenant Disputes any item in any such invoice,
Tenant shall pay the undisputed items in such invoice and negotiate in good faith with Landlord
with respect to any such amounts in Dispute.

               (iii) Mechanics Liens.
With respect to any mechanics lien filed against the Premises
or the Project in connection with the services described in Section 7(e)(iii), Landlord shall: (A)
pay the amount of such lien and cause such lien to be released of record; or (B) diligently
contest such lien. Landlord shall take such action within (I) ten (10) days after Landlord’s
receipt of written notice of the filing of such lien; or (II) such earlier time period as may be
necessary to prevent the forfeiture of the Premises, the Project or any interest of Landlord
therein or the imposition of a civil or criminal fine with respect thereto.

               (iv) Tenant Responsible For Amounts Owed to Tenant Contractors. Landlord and Tenant
acknowledge and agree that their relationship is and shall be solely that of “landlord-tenant,”
thereby excluding a relationship of “owner-contractor,” “owner-agent” or other similar
relationships. All Tenant Contractors and any other Persons now or hereafter contracting with
Tenant, any Tenant Contractor or any other Tenant Party for the furnishing of any labor, services,
materials, supplies or equipment with respect to any portion of the Premises, at any time from the
date hereof until the end of the Term, are hereby charged with notice that Person shall look
exclusively to Tenant to obtain payment for same. Nothing herein shall be deemed a consent by
Landlord to any liens being placed upon the Premises, the Project or Landlord’s interest therein
due to any work performed by a Tenant Contractor or deemed to give any Tenant Contractor any right
or interest in any funds held by Landlord to reimburse Tenant for any portion of the cost of such
work. Tenant shall defend, indemnify and hold harmless Landlord and its agents and representatives
from and against all claims, demands, causes of action, suits, judgments, damages and expenses
(including attorneys’ fees) in any way arising from or relating to the failure by any Tenant Party
to pay for any work performed or materials furnished by a Tenant Contractor at the request of a
Tenant Party. This indemnity provision shall survive termination or expiration of this Lease.

     8. 
Tenant’s Use 
of Premises. Tenant shall: (a) use the Premises only for
the Permitted Use; (b) comply with Applicable Laws relating to the use, condition, access to, and
occupancy of the Premises; (c) not
commit waste

10

 

or overload the Building’s Structure or the Building’s Systems; (d) not subject the Premises to
use that would damage the Premises; (e) not use the Premises in any manner that is disreputable;
(f) not use the Premises in any manner that creates extraordinary fire hazards; (g) not use the
Premises in any manner that results in an increased rate of insurance on the Building or its
contents; (h) not use the Premises to store any Hazardous Materials, other than typical office
supplies such as photocopier toner, and then only in compliance with Applicable Laws; (i) conduct
Tenant’s business in the Premises and control each other Tenant Party located in the Project so as
not to create any nuisance or unreasonably interfere with other tenants or Landlord in its
management of the Building; (j) pay Landlord upon Tenant’s receipt of a written request for the
amount of the Premises’ pro-rata share of any documented increase in the Building’s insurance
premiums caused directly by a Tenant Party’s breach of any provision herein or Tenant’s vacating
the Premises in breach hereof (and Landlord’s acceptance of such payment shall not waive any of
Landlord’s other rights herein); (k) as between Landlord and Tenant, bear the risk of complying
with the Disabilities Acts in the Premises; and (1) continuously operate its retail banking
business in the Premises. As between Landlord and Tenant, Landlord shall bear the risk of
complying with the Disabilities Acts in the common areas of the Building, other than compliance
that is necessitated by the use of the Premises for other than the Permitted Use or as a result of
any alterations or additions, including any initial tenant improvement Work, made by or on behalf
of a Tenant Party (which risk and responsibility shall be borne by Tenant).

     9. Assignment and Subletting.

          (a) Transfers.
Except as provided in Section 9(h), Tenant shall not engage in a Transfer
without the prior written consent of Landlord.

          (b) Standards For Landlord’s Consent to Transfers.
Landlord shall not unreasonably withhold,
delay or condition its consent to any assignment or subletting of the Premises, provided that the
proposed transferee: (i) is creditworthy: (ii) has a good reputation in the business community;
(iii) will use the Premises for the Permitted Use and will not use the Premises in any manner that
would conflict with any exclusive use agreement or other similar agreement entered into by
Landlord with any other tenant of the Building; (iv) will not use the Premises, Building or
Project in a manner that would materially increase the pedestrian or vehicular traffic to the
Premises, Building or Project; (v) is not a governmental entity, or subdivision or agency thereof;
(vi) is not another occupant of the Building; and (vii) is not a Person with whom Landlord is
then, or has been within the six (6)-month period prior to the time Tenant seeks to enter into
such assignment or subletting, negotiating to lease space in the Building or any Affiliate of any
such Person. Landlord may, in its sole discretion, withhold its consent to a Transfer: described
in subparagraphs (i) through (vii) above if Tenant has committed an Event of Default that has not
been cured at the time Tenant has requested such Transfer.

          (c) Tenant’s Request for Consent. At least fifteen (15) Business Days prior to the effective
date of any proposed Transfer, Tenant shall provide Landlord with: (i) a written description of
all terms and conditions thereof; (ii) copies of the proposed documentation; (iii) name and
address of the proposed transferee; (iv) reasonably satisfactory information about the proposed
transferee’s business and business history; (v) the proposed transferee’s proposed use of the
Premises; (vi) the proposed transferee’s banking, financial and other credit information; (vi)
general references sufficient to enable Landlord to determine the proposed transferee’s
creditworthiness and character; and (vii) a one thousand dollar ($1,000) fee to defray Landlord’s
expenses in reviewing such Transfer request. Tenant shall reimburse Landlord immediately upon
request for Landlord’s reasonable attorneys’ fees incurred in connection with considering any
request for consent to such a Transfer.

          (d) Conditions to Landlord’s Consent to Transfers. Each proposed transferee approved by
Landlord hereunder shall deliver to Landlord a written agreement under which such transferee
expressly assumes Tenant’s obligations hereunder. Notwithstanding the foregoing, if Tenant
Transfers less than all of the space in the Premises to an approved transferee, such transferee
shall be liable only for obligations under this Lease that are properly allocable to the space
subject to such Transfer for the period thereof. After the consummation of any approved Transfer
or Permitted Transfer: (i) Tenant shall be released from its obligations hereunder; and (ii)
transferee shall be solely liable for Tenant’s obligations and performance hereunder. Landlord’s
consent to any Transfer shall not waive Landlord’s rights as to any subsequent Transfers.

          (e) Event of Default. If an Event of Default occurs while the Premises or any part thereof are
subject to a Transfer, Landlord may, in addition to its other remedies hereunder, collect directly
from such transferee all rents becoming due to Tenant and apply such rents against Rent. Tenant
authorizes its transferees to make payments of

11

 

Rent directly to Landlord upon receipt of notice from Landlord to do so following the occurrence
of an Event of Default hereunder.

          (f) Improvements Necessitated by Sublease or Assignment. Landlord shall provide Tenant with a
written invoice setting forth Landlord’s actual cost of any demising walls or other improvements
necessitated by a proposed subletting or assignment and all information and documentation
necessary to support the validity and accuracy of all such costs incurred. Tenant shall pay such
costs to Landlord within thirty (30) days after Landlord has delivered such invoice to Tenant,
provided that no such amount is the subject of a good faith Dispute. If Tenant Disputes any item in
any such invoice, Tenant shall pay the undisputed items in such invoice and negotiate in good
faith with Landlord with respect to any such amounts in Dispute.

          (g) Attornment by Subtenants. Each sublease by Tenant hereunder shall be subject and
subordinate to this Lease and to the matters to which this Lease is or shall be subordinate, and
each subtenant by entering into a sublease is deemed to have agreed that in the event of
termination, re-entry or dispossession by Landlord under this Lease, Landlord may, at its option,
take over all of the right, title and interest of Tenant, as sublandlord, under such sublease, and
such subtenant shall, at Landlord’s option, attorn to Landlord pursuant to the then executory
provisions of such sublease, except that Landlord shall not be: (i) liable for any previous act or
omission of Tenant under such sublease; (ii) subject to any counterclaim, offset or defense that
such subtenant might have against Tenant; (iii) bound by any previous modification of such
sublease not approved by Landlord in writing or by any rent or additional rent or advance rent
that such subtenant might have paid for more than the current month to Tenant, and all such rent
shall remain due and owing, notwithstanding such advance payment; (iv) bound by any security or
advance rental deposit made by such subtenant that is not delivered or paid over to Landlord and
with respect to which such subtenant shall look solely to Tenant for refund or reimbursement; or
(v) obligated to perform any work in the subleased space or to prepare it for occupancy, and in
connection with such attornment, the subtenant shall execute and deliver to Landlord any
instruments Landlord may reasonably request to evidence and confirm such attornment. Each
subtenant or licensee of Tenant shall be deemed, automatically upon and as a condition of its
occupying or using the Premises or any part thereof, to have agreed to be bound by the terms and
conditions set forth in this Section 9(g). The provisions of this Section 9(g) shall be
self-operative, and no further instrument shall be required to give effect thereto.

          (h) Permitted Transfers.

               (i) Categories of Permitted Transferees. Notwithstanding Section 9(a), Tenant may
engage in a Permitted Transfer of all or part of Tenant’s interest in this Lease or all or part of
the Premises to any and all of the following Permitted Transferees without the written consent of
Landlord:

                    (A) Tenant Affiliates. An Affiliate of Tenant.

                    (B) Survivor of Merger or Consolidation With Tenant. Any corporation, limited
partnership, limited liability partnership, limited liability company or other business Person in
which or with which Tenant, or its corporate successors or assigns, is merged or consolidated, in
accordance with applicable statutory provisions governing merger and consolidation of business
entities, so long as: (A) Tenant’s obligations hereunder are assumed by the entity surviving such
merger or created by such consolidation; and (B) the Tangible Net Worth of the surviving or
created Person is not less than the Tangible Net Worth of Tenant as of the date hereof; or

                    (C) Person Acquiring Substantially All of Tenant’s Assets. Any corporation, limited
partnership, limited liability partnership, limited liability company or other business Person
acquiring all or substantially all of Tenant’s assets if such Person’s Tangible Net Worth after
such acquisition is not less than the Tangible Net Worth of Tenant as of the date hereof.

               (ii) Tenant’s Obligations Following Permitted Transfers. Tenant shall: (A) promptly
notify Landlord of any such Permitted Transfer; (B) remain liable for the performance of all of
the obligations of Tenant hereunder, or if Tenant no longer exists because of a merger,
consolidation, or acquisition, the surviving or acquiring Person shall expressly assume in writing
Tenant’s obligations hereunder; and (C) furnish Landlord the following information no later than
30 days after the effective date of any Permitted Transfer; (I) copies of the instrument effecting
any of the foregoing Transfers; (II) documentation establishing Tenant’s satisfaction of the
foregoing

12

 

requirements applicable to any such Transfer; and (III) evidence of insurance required hereunder
with respect to the Permitted Transferee.

               (iii) Transferee’s Obligations Following Permitted Transfer. Each Permitted
Transferee shall: (A) comply with all of the terms and conditions of this Lease, including the
Permitted Use; and (B) not use the Premises in violation of any other agreements affecting the
Premises or the Building, Landlord or other tenants of the Building.

               (iv) Landlord’s Rights Following Permitted Transfer. The occurrence of a Permitted
Transfer shall not waive Landlord’s rights as to any subsequent Transfers. Any subsequent Transfer
by a Permitted Transferee shall be subject to the terms of this
Section 9.

     10. 
Insurance.

          (a) Tenant’s Insurance. Tenant will throughout the Term (and any other period when Tenant is
in possession of the Premises) carry and maintain, at its sole cost and expense, the following
types of insurance, which shall provide coverage on an occurrence basis, in the amounts specified
with deductible amounts reasonably satisfactory to Landlord:

     (i) Commercial General Liability Insurance. Commercial General Liability
(“CGL”) insurance covering claims arising from personal injury, death and property damage
occurring in or about the Premises, the Building and the Project with minimum limits of
$1,000,000.00 per occurrence and $2,000,000.00 general aggregate. The CGL policy shall
include Contractual Liability coverage.

     (ii) Comprehensive Automobile Liability Insurance. Comprehensive Automobile
Liability insurance with a limit of not less than $1,000,000.00 per occurrence for bodily
injury, $500,000.00 per person and $100,000.00 property damage or a combined single limit
of $1,000,000.00 for both owned and non-owned vehicles.

     (iii) Excess Liability Insurance. Tenant shall also carry and maintain Excess
Liability insurance with a limit of not less than $5,000,000.00 per occurrence.

     (iv) Property Insurance. Insurance of personal property, decorations, trade
fixtures, furnishings, equipment, alterations, leasehold improvements and betterments made
by Tenant on the full replacement value of Tenant’s property. Tenant’s policy will also
include business interruption/extra expense coverage in amounts sufficient to insure six
(6) months of interrupted business operations at the Premises.

     (v) Workers’ Compensation and Employers’ Liability Insurance. Workers’
Compensation insurance covering all employees of Tenant, as required by the laws of the
State of Florida.

          Policy Form. All policies referred to above shall: (i) be taken out with insurers
licensed to do business in Florida having an A.M. Best’s rating of A or better; (ii) name Landlord
and Landlord’s property manager as an additional insured; (iii) be non-contributing with, and
shall apply only as primary and not as excess to any other insurance available to the Landlord or
any mortgagee of Landlord; and (iv) contain an obligation of the insurers to endeavor to notify
the Landlord not less than thirty (30) days prior to the termination of any such policy. Tenant
shall provide certificates of insurance on Acord Form 25-S on or before the Commencement Date and
thereafter at times of renewal or changes in coverage or insurer, and if required by mortgagee
copies of such insurance policies certified to Tenant’s insurer as being complete and current
promptly upon request. If (a) the Tenant fails to take out or to keep in force any insurance
referred to in this Section 10, or should any such insurance not be approved by either the
Landlord or any mortgagee, and (b) the Tenant does not commence and continue to diligently cure
such default within two (2) Business Days after written notice by the Landlord to Tenant
specifying the nature of such default then the Landlord has the right, without assuming any
obligation in connection therewith, to procure such insurance at the sole cost of the Tenant, and
all outlays by the Landlord shall be paid by the Tenant to the Landlord without prejudice to any
other rights or remedies of the Landlord under this Lease. The Tenant shall not keep or use in the
Premises any article that may be prohibited by any fire or casualty insurance policy in force from
time to time covering the Premises or the Project.

13

 

          (b) Landlord’s Insurance. During the Term, Landlord will carry and maintain the following
types of insurance: (i) builders risk insurance during construction of the Building; (ii) property
insurance on the Project covering “All Risks” perils in an amount equal to the full replacement
cost of the Project (excluding any property with respect to which the Tenant and other tenants are
obliged to insure pursuant to Section 10 or similar sections of their respective leases); and (iii)
commercially reasonable commercial general liability insurance with respect to the Project.
Landlord may maintain any other commercially reasonable insurance coverages relating to the Project
or Landlord’s operations therein.

          (c) Additional Landlord Insurance. Landlord may, but shall not be obligated to, (i) maintain
such other insurance and additional coverages relating to the Project and its operation as
Landlord shall from time to time deem necessary; (ii) include the cost of the foregoing insurance
relating to the Project in Operating Costs; and (iii) maintain the foregoing insurance coverages
for Landlord’s sole benefit and under Landlord’s sole control, and Tenant shall have no right or
claim to any proceeds thereof or any other rights thereunder.

          (d) Evidence of Landlord’s Insurance. Landlord shall: (i) furnish to Tenant evidence that
Landlord has obtained all insurance coverages required hereunder at least ten (10) days prior to
the Commencement Date and fifteen (15) days prior to each renewal of such insurance; (ii) obtain a
written obligation from each insurance company to endeavor to notify Tenant at least thirty (30)
days before an insurance policy is cancelled or materially changed; and (iii) obtain each such
insurance policy from an insurer with an A.M. Best rating of A or better. If Landlord fails to
comply with the foregoing insurance requirements or to deliver to Tenant the certificates or
evidence of coverage required herein, Tenant, in addition to any other remedy available pursuant
to this Lease or otherwise, may, after providing Landlord, five (5) Business Days prior notice,
obtain such insurance and Tenant shall pay to Landlord on demand the premium costs thereof.

     11. Indemnification.

          (a) Tenant’s Indemnification Obligations. Tenant shall defend, indemnify and hold Landlord,
its partners, Affiliates and respective officers, directors, employees, agents, successors and
permitted assigns harmless from and against, and shall reimburse Landlord or them for, any Losses
arising from, in connection with or resulting from:

               (i) any occurrence in the Premises or arising out of the installation, operation,
maintenance, repair or removal of any of Tenant’s Off-Premises Equipment, unless caused by the
negligence, gross negligence, fault or strict liability of Landlord or its agents or contractors;

               (ii) Tenant’s breach of, or any false, inaccurate, untrue or incomplete representation or
warranty herein;

               (iii) Tenant’s breach, non-fulfillment or non-performance of any covenant, obligation, duty,
condition or action required of Tenant pursuant hereto; and/or

               (iv) Tenant’s willful misfeasance, bad faith, fraud, negligence and/or gross negligence in
the performance or failure to perform Tenant’s obligations, duties or covenants herein.

          (b) Landlord’s Indemnification Obligations. Landlord shall defend, indemnify and hold Tenant,
its stockholders, Affiliates and respective officers, directors, employees, agents, successors and
permitted assigns harmless from and against, and shall reimburse Tenant or them for, any Losses
arising from, in connection with or resulting from:

               (i) any occurrence in the Building’s common areas which do not arise out of the fault or
negligence of Tenant, its agents, contractors, employees or invitees;;

               (ii) Landlord’s breach of, or any false, inaccurate, untrue or incomplete representation or
warranty herein;

               (iii) Landlord’s breach, non-fulfillment or non-performance of any material covenant,
obligation, duty, condition or action required of Tenant pursuant hereto; and/or

14

 

               (iv) Landlord’s willful misfeasance, bad faith, fraud, negligence and/or gross negligence in
the performance or failure to perform Landlord’s obligations, duties or covenants herein.

          (c) Procedures for Indemnification.

               (i) Written
Notice of Indemnification Claim. An Indemnification Claim shall be made
by an Indemnified Person by delivering a written notice to the Indemnifying Person and it’s legal
Representative requesting indemnification and specifying in reasonable detail the basis on which
indemnification is sought and the amount of asserted Damages and, in the case of a Third Person
Claim, containing (by attachment or otherwise) such other information as such Indemnified Person
shall have concerning such Third Person Claim.

               (ii) Third Person Claims. If the Indemnification Claim involves a Third Person Claim,
the Indemnified Person and the Indemnifying Person shall observe the procedures set forth in
Section 11(d) hereof.

               (iii) Other Claims. If the Indemnification Claim involves a matter other than a Third
Person Claim, the Indemnifying Person’s legal Representative shall have thirty (30) days to object
to such Indemnification Claim by delivering a written notice of such objection to such Indemnified
Person specifying in reasonable detail the basis for such objection. Failure to so object in a
timely manner shall constitute a final and binding acceptance of the Indemnification Claim by the
Indemnifying Person’s Representative on behalf of all Indemnifying Persons, and the
Indemnification Claim shall be paid in accordance with Section 11(e) hereof.

          (d) Third Person Claims. The Parties’ obligations and liabilities hereunder with respect to a
Third Person Claim shall be subject to the following terms and conditions:

               (i) Written Notice of Third Person Claim. The Indemnified Person shall give the
Indemnifying Person’s Representative written notice of a Third Person Claim promptly after receipt
by the Indemnified Person of notice thereof, and the Indemnifying Person’s Representative, on
behalf of the Indemnifying Persons, may undertake the defense, compromise and settlement thereof by
Representatives of its own choosing reasonably acceptable to the Indemnified Person. The failure of
the Indemnified Person to notify the Indemnifying Person’s Representative of such Claim shall not
relieve the Indemnifying Persons of any Liability that the Indemnifying Persons may have with
respect to such Claim except to the extent the Indemnifying Person’s Representative demonstrates
that the defense of such Claim is prejudiced by such failure.

               (ii) Acknowledgement of Obligation to Indemnify. The Indemnifying Person’s assumption
of the defense, compromise or settlement of any such Third Person Claim shall be the Indemnifying
Person’s acknowledgment of its obligation to indemnify the Indemnified Person with respect to such
Claim hereunder, unless the Indemnifying Person gives written notice to the Indemnified Person
within ten (10) days after receipt of the Indemnified Person’s notice that it Disputes its
liability to Indemnified Person with respect to such Third Person Claim notwithstanding its
assumption of the defense thereof.

               (iii) Indemnified Person’s Participation in Defense. If the Indemnified Person
desires to participate in, but not control, any such defense, compromise or settlement, it may do
so at its sole cost and expense. If, however, the Indemnifying Person’s Representative fails or
refuses to undertake the defense of such Third Person Claim within ten (10) days after written
notice of such Claim has been given to the Indemnifying Person Representative by the Indemnified
Person, the Indemnified Person shall have the right to undertake the defense, compromise and/or
settlement of such Claim with counsel of its own choosing. In the circumstances described in the
preceding sentence, the Indemnified Person shall, promptly upon its assumption of the defense of
such Claim, be deemed to have made an Indemnification Claim that is not a Third Person Claim for
the purposes of the procedures set forth herein.

               (iv) Indemnified Person’s Control of Defense.

                    (A) If, in the reasonable opinion of the Indemnified Person, any Third Person Claim or the
Action or resolution thereof involves an issue or matter that could reasonably have a Material
Adverse Effect on the Indemnified Person’s business, operations, assets, properties or prospects,
including, but not limited to, the administration of the Tax returns and responsibilities under
the Tax Laws of the Indemnified Person:

15

 

                    (I) the Indemnified Person shall have the right to control the defense, compromise
and/or settlement of such Third Person Claim undertaken by the Indemnifying Person’s
Representative;

                    (II) the Indemnified Person shall initially pay the fees, costs and expenses of the
Indemnified Person’s legal, accounting and consulting Representatives or any other Person retained
by the Indemnified Person in connection with the aforementioned defense, compromise and/or
settlement; and

                    (III) such fees, costs, expenses and all other Damages paid, suffered or incurred by the
Indemnified Person resulting from, based upon or arising out of such Third Person Claim shall be
included as part of the indemnification obligations of the Indemnifying Persons hereunder.

               (B) If the Indemnified Person shall elect to exercise such right, the Indemnifying Person’s
Representative shall have the right to participate in, but not control, the defense, compromise
and/or settlement of such Third Person Claim at its sole cost and expense.

          (v) Certain Settlements
By The Indemnified Person Are Subject To The Indemnifying Person’s Consent. No settlement of a Third Person Claim involving the asserted Liability of
any Indemnifying Person under this Article shall be made without the prior written consent by or
on behalf of the Indemnifying Person’s Representative, which consent shall not be unreasonably
withheld or delayed. Consent shall be presumed in the case of settlements of ten thousand dollars
($10,000) or less where the Indemnifying Person’s Representative has not responded within ten (10)
Business Days of such Representative’s receipt of written notice of such proposed settlement.

          (vi) Certain Settlements By The Indemnifying Person Are Subject to The Indemnified
Person’s Consent. If the Indemnifying Person’s Representative assumes the defense of such a
Third Person Claim:

               (A) no compromise or settlement thereof may be effected by the Indemnifying Person’s
Representative without the Indemnified Person’s consent unless:

                    (I) there is no finding or admission of any violation of Applicable Requirements or any
violation of the rights of any Person and no effect on any other Claim that may be made against
the Indemnified Person;

                    (II) the sole relief provided is monetary damages that are paid in full by the Indemnifying
Persons; and

                    (III)
the compromise or settlement includes, as an unconditional term thereof, the giving by
the Claimant or the plaintiff to the Indemnified Person of a release, in form and substance
satisfactory to the Indemnified Person, from all Liability in respect of such Third Person Claim;
and

                    (IV) the Indemnified Person shall have no Liability with respect to any compromise or
settlement thereof effected without its consent.

          (vii)
Cooperation; Participation of Counsel; Access to Records.

               (A) Third Person Claims. In connection with the defense, compromise or settlement of
any Third Person Claim, the Parties shall execute such powers of attorney as may reasonably be
necessary or appropriate to permit participation of the legal Representative selected by any Party
and, as may reasonably be related to any such Claim or Action, shall provide access to the legal,
accounting and other Representatives of each Party during normal business hours to all properties,
personnel, books, tax records, contracts, commitments and all other business records of such other
Party and will furnish to such other Party copies of all such documents as may reasonably be
requested (certified, if requested).

               (B) Agency Claims. Intentionally deleted.

          (viii) Statutes of Limitation. Subject to the approval of a Party’s insurance
carrier, if a Third Person Claim is brought against a Party with respect to which either Party may
have a Claim against the other, the Parties shall execute a statute of limitation tolling
agreement as to such Claims until the Third Person Claim is resolved.

16

 

          (e) Payment of Indemnification Claim. Upon determination of the amount of an Indemnification
Claim, whether by agreement between the Indemnifying Person’s Representative and the Indemnified
Person or by an arbitration award or by any other final adjudication, the Indemnifying Persons
shall pay the amount of such Indemnification Claim within thirty (30) days of the date such
amount is determined. Thereafter, the amount of such Indemnification Claim shall bear interest at
a rate equal to ten percent (10%) per annum.

          (f) Subrogation. Upon payment in full of any Indemnification Claim or the payment of any
judgment or settlement with respect to a Third Person Claim, the Indemnifying Persons shall be
subrogated to the extent of such payment to the rights of the Indemnified Person against any
Person with respect to the subject matter of such Indemnification Claim or Third Person Claim.

          (g) Limitation of Liability. IN NO EVENT SHALL EITHER PARTY BE LIABLE FOR ANY SPECIAL,
INCIDENTAL, INDIRECT, PUNITIVE, EXEMPLARY, OR CONSEQUENTIAL DAMAGES OF ANY KIND IN CONNECTION
WITH THIS LEASE, EVEN IF SUCH PARTY HAS BEEN INFORMED IN ADVANCE OF THE POSSIBILITY OF SUCH
DAMAGES.

          (h) Survival
of Indemnification. The indemnities set forth in this
Section 11 shall
survive termination or expiration of this Lease and shall not terminate or be waived, diminished
or affected in any manner by any abatement or apportionment of Rent under any provision of this
Lease.

     12. Subordination; Attornment; Notice to Landlord’s Mortgagee.

          (a) Subordination. This Lease shall be subordinate to any Mortgage or Primary Lease that now
or hereafter covers all or any part of the Premises. Any Landlord’s Mortgagee may unilaterally
elect at any time to make this Lease superior to its Mortgage, Primary Lease or other interest
in the Premises by so notifying Tenant in writing. The provisions of this Section 12 shall be
self-operative and no further instrument of subordination shall be required. Notwithstanding the
foregoing, Tenant shall take the following actions:

               (i) Documentation Subordinating Lease to Mortgage or Primary Lease. Tenant shall: (A)
confirm the subordination of this Lease to any such Mortgage or Primary Lease by executing such
documentation as Landlord’s Mortgagee may reasonably request to evidence such subordination; (B)
cause such documentation to include a subordination, non-disturbance and attornment agreement;
(C) if required, cause such documentation to be in recordable form; (D) return such documentation
to Landlord or such other Person designated by Landlord within ten (10) days after written
request therefor; or

               (ii) Documentation Subordinating Mortgage or Primary Lease to This Lease. If the Landlord’s
Mortgagee so elects, Tenant shall execute such documentation as Landlord’s Mortgage may
reasonably request to evidence the subordination of such Mortgage or Primary Lease to this Lease.

          Landlord shall direct Landlord’s Mortgagee to execute a subordination, nondisturbance and
attornment agreement with respect to this Lease and the Premises in such form as may be
reasonably acceptable to Tenant.

          (b) Attornment. Tenant shall attorn to any Person succeeding to Landlord’s interest in the
Premises, whether by purchase, foreclosure, deed in lieu of foreclosure, power of sale,
termination of lease, or otherwise, upon such Person’s request, and shall execute such agreements
confirming such attornment as such Person may reasonably request.

          (c) Notice to Landlord’s Mortgagee. Landlord shall provide to Tenant in writing
the name, address and telephone numbers of each Landlord’s Mortgagee. Tenant shall not seek to
enforce any remedy it may have for any default by Landlord without first: (i) providing to each
such Landlord’s Mortgagee written notice of such proposed enforcement, specifying the default in
reasonable detail; and (ii) affording each such Landlord’s Mortgagee a reasonable opportunity to
perform Landlord’s obligations hereunder.

          (d) Landlord Obligations. Landlord shall:

               (i) deposit into a Special Deposit Account any and all additional rent or advance rent that
Tenant may pay hereunder for more than the current month to Landlord or any successor thereto;

17

 

               (ii) deposit into a Special Deposit Account any and all security or advance rental deposits
made by Tenant hereunder;

               (iii) not withdraw any portion of the funds in a Special Deposit Account unless such funds
represent: (A) rents, security or rental deposits that are currently due and payable hereunder; or
(B) security or advance rental deposits that Landlord intends to forward to a Landlord’s Mortgagee
that has succeeded to Landlord’s interests hereunder;

               (iv) provide Tenant with written documentation of each Mortgage and Primary Lease that
Landlord has entered into with each Landlord’s Mortgagee, including documentation identifying each
termination, amendment or modification hereto that Landlord may engage in with and without such
Landlord’s Mortgagee’s consent;

               (v) not terminate, amend or modify this Lease without obtaining any consent required by a
Landlord’s Mortgagee;

               (vi) with respect to any termination, amendment or modification of this Lease, provide Tenant
with: (A) Landlord’s written representation and warranty that Landlord received written consent
from each Landlord’s Mortgagee in connection therewith (or Landlord’s written representation and
warranty that no such consent was required in connection with such action); and (B) each
applicable Landlord’s Mortgagee’s written certification that Landlord’s Mortgagee provided written
consent to Landlord in connection therewith (or Landlord’s Mortgagee’s written certification that
no such consent was required in connection with such action).

     13. Rules And Regulations. Tenant shall comply with the rules and
regulations of the Project which are attached hereto as
Exhibit C. Landlord may, from time
to time, change such rules and regulations for the safety, care, or cleanliness of the Project and
related facilities, provided that such changes shall: (i) apply to all tenants of the Project;
(ii) not diminish or unreasonably interfere with Tenant’s use of the Premises; (iii) be enforced
by Landlord in a non-discriminatory manner. Tenant shall cause each Tenant Party to comply with
such rules and regulations.

     14. Condemnation.

          (a) Total Taking. This Lease shall terminate as of the date of a Taking of the entire
Building or Premises.

          (b) Partial Taking — Tenant’s Rights. If any part of the Building becomes subject to a Taking
and such Taking would prevent Tenant from conducting on a permanent basis its business in the
Premises and the Building in a manner substantially the same as that conducted immediately before
such Taking, then Tenant may terminate this Lease as of the date of such Taking by giving written
notice to Landlord within one hundred and twenty (120) days after such Taking, and Basic Rent and
Additional Rent shall be apportioned as of the date of such Taking. If Tenant does not terminate
this Lease within one hundred and twenty (120) days after the
Taking, Rent shall be abated on a
reasonable basis as to that portion of the Premises rendered untenantable by the Taking.

          (c) Partial Taking — Landlord’s Rights. If any material portion, but less than all, of the
Building becomes subject to a Taking, or if Landlord is required to pay any of the proceeds
arising from a Taking to a Landlord’s Mortgagee, then Landlord may terminate this Lease by
delivering written notice thereof to Tenant within one hundred and twenty (120) days after such
Taking, and Basic Rent and Additional Rent shall be apportioned as of the date of such Taking. If
Landlord does not so terminate this Lease within one hundred and twenty (120) days after such
Taking, this Lease will continue, but if any portion of the Premises has been taken, Rent shall
abate as provided in the last sentence of Section 14(b).

          (d) Temporary Taking. The following shall apply if all or any portion of the Building becomes
subject to a Taking for a limited period of time:

               (i) Tenant Able to Conduct Business As Usual. If any part of the Building becomes
subject to such a temporary Taking and Tenant is able to continue conducting its business in the
Premises and the Building in a manner substantially the same as that conducted immediately before
such Taking, this Lease shall remain in full force and effect and Tenant shall continue to perform
all of the terms, conditions and covenants of this Lease, including the payment of Basic Rent and
all other amounts required hereunder.

18

 

               (ii) Tenant Unable to Conduct Business As Usual.

                    (A) Abatement. If any part of the Building becomes subject to such a temporary Taking
and such Taking would prevent Tenant from conducting on its business in the Premises and the
Building in a manner substantially the same as that conducted immediately before such Taking for:
(A) a period of seven (7) consecutive days following such Taking, Tenant shall receive a complete
abatement of Rent for each consecutive day after such 7-day period that Tenant is so prevented from
using the Premises or Building; or (B) 15 days within any 30-day period, Tenant shall receive a
complete abatement of Rent for each such day within such 30-day period that Tenant is so prevented
from using the Premises or Building.

                    (B) Termination. Tenant may, in its sole discretion, terminate this Lease immediately
and without penalty or other cost if any part of the Building becomes subject to such a temporary
Taking and such Taking would prevent Tenant from conducting its business in the Premises in a
manner substantially the same as that conducted immediately before such Taking for a period of 45
consecutive days.

                    (C) Condemnation Awards. Tenant shall be entitled to receive the entire award made in
connection with any temporary condemnation or other taking of the Premises attributable to any
period within the Term. Landlord shall be entitled to the entire award for any such temporary
condemnation or other taking that: (I) relates to a period after the expiration of the Term; or
(II) is allocable to the cost of restoration of the Premises. If any such temporary condemnation
or taking terminates prior to the expiration or termination of the Term, Tenant shall use the
portion of the award attributable to Tenant to restore the Premises as nearly as possible to the
condition prior to the condemnation or other taking; provided, however, that Tenant shall
not be obligated to use any other funds to restore the Premises.

               (e) Award. Except as set forth in Section 14(d)(ii)(C), Landlord shall receive the entire
award or other compensation for the Land, the Building and other improvements that are subject to
a Taking. Notwithstanding the foregoing, Tenant may separately pursue a Claim (to the extent it
will not reduce Landlord’s award) against the condemnor for the value of Tenant’s personal
property which Tenant is entitled to remove under this Lease, moving costs, loss of business, and
other claims it may have.

     15 Fire or Other Casualty.

          (a) Repair Estimate. If the Premises or the Building are damaged by a Casualty, Landlord
shall, within ninety (90) days after such Casualty, deliver a Damage Notice to Tenant containing a
good faith estimate of the time needed to repair the damage caused by such Casualty.

          (b) Tenant’s Rights. Tenant may terminate this Lease immediately upon providing written
notice thereof to Landlord if: (i) a portion of the Building or Premises is damaged by Casualty
such that Tenant is prevented from conducting its business in the Premises or the Building in a
manner substantially the same as that conducted immediately before such Casualty; and (ii)
Landlord estimates that the damage caused thereby cannot be repaired within 180 days from the date
of such Casualty (or, regardless of such estimate, if such damages are not repaired within 180
days from the date of such Casualty).

          (c) Landlord’s Rights. Landlord may terminate this Lease by giving written notice of its
election to terminate within 30 days after the Damage Notice has been delivered to Tenant if a
Casualty damages the Premises or a material portion of the Building and: (i) Landlord estimates
that the damage to the Premises cannot be repaired within 180 days from the date of such Casualty;
(ii) the damage to the Premises exceeds fifty percent (50%) of the replacement cost thereof
(excluding foundations and footings), as estimated by Landlord, and such damage occurs during the
last two (2) years of the Term; (iii) the damage to the Premises exceeds fifty percent (50%) of
the replacement cost thereof (excluding foundations and footings) and is not substantially covered
by Landlord’s insurance policies by reason of an exclusion from such policies outside of
Landlord’s control (e.g., such policies exclude Casualties caused by terrorist attack); or (iv)
Landlord is required to pay the insurance proceeds arising out of the Casualty to a Landlord’s
Mortgagee.

          (d) Repair Obligation. If neither Party elects to terminate this Lease following a Casualty,
Landlord shall, within a commercially reasonable time after the date of such Casualty: (i) begin
to repair the Premises; and (ii) proceed with commercially reasonable diligence to restore the
Premises to substantially the same condition as they

19

 

existed immediately before such Casualty. Notwithstanding the foregoing, Landlord shall not be
required to repair or replace any: (A) alterations or betterments within the Premises, which
shall be promptly and with due diligence repaired and restored by Tenant at Tenant’s sole cost
and expense; or (B) furniture, equipment, trade fixtures or personal property in the Premises or
the Building that is owned or leased by Tenant or any Person other than Landlord. Landlord’s
obligation to repair or restore the Premises shall be limited to the extent of the insurance
proceeds actually received by Landlord for the Casualty in question; provided, however, that any
shortfall in insurance proceeds caused by Landlord’s failure to comply with its insurance
obligations in Section 10(b) shall be deemed to be a Landlord Event of Default. If this Lease is
terminated under the provisions of this Section 15,
 Landlord shall be entitled to the full
proceeds of the insurance policies providing coverage for all alterations, improvements and
betterments in the Premises (and, if Tenant has failed to maintain insurance on such items as
required by Section 15(a) of this Lease, Tenant shall pay Landlord an amount equal to the
proceeds Landlord would have received had Tenant maintained insurance on such items as required
by this Lease).

               (e) Abatement of Rent. If the Premises are damaged by Casualty, Rent for the portion of the
Premises rendered untenantable by the damage shall be abated on a reasonable basis from the date
of such damage until the: (i) completion of Landlord’s repairs; or (ii) date of termination of
this Lease by Landlord or Tenant as provided above. Notwithstanding the foregoing, Tenant shall
continue to pay Rent without abatement if a Tenant Party was the direct cause of the Casualty
causing such damage.

     16. Personal Property Taxes. Tenant shall be liable for all taxes
levied or assessed against personal
property, furniture, or fixtures placed by Tenant in the Premises or in or on the Building or
Project. Tenant shall repay to Landlord within thirty (30) days following written request
therefore any taxes that Landlord has elected to pay relating to: (i) taxes for which Tenant is
liable and that are levied or assessed against Landlord or Landlord’s property; and/or (ii) any
increase in the assessed value of Landlord’s property by inclusion of such Tenant’s personal
property, furniture or fixtures. Landlord shall not pay such amount if: (A) Tenant notifies
Landlord that Tenant will contest the validity or amount of such taxes before Landlord makes such
payment; (B) Tenant thereafter diligently proceeds with such contest in accordance with
Applicable Law; and (C) the non-payment thereof does not pose a threat of loss or seizure of the
Project or Landlord’s interest therein or impose any fee or penalty against Landlord.

     17. Events of Default. Each of the following occurrences
shall be an Event of Default:

               (a) Tenant Event of Default.

                    (i) Payment Default. Tenant’s failure to pay Rent by the first day of each month
during the Term of this Lease, unless subject to abatement or otherwise excused hereunder.

                    (ii) Estoppel. Tenant fails to provide any estoppel certificate after Landlord’s
written request therefor pursuant to Section 23(d) and such failure shall continue for five (5)
Business Days after Landlord’s second written notice thereof to Tenant.

                    (iii) Insurance. Tenant fails to procure, maintain and deliver to Landlord evidence
of the insurance policies and coverages as required under Section 10(a) and such failure shall
continue for five (5) Business Days after Landlord’s second written notice thereof to Tenant.

                    (iv) Mechanic’s Liens. Tenant fails to pay and release of record, or diligently
contest and bond around, any mechanic’s lien filed against the Premises or the Project for any
work performed, materials furnished, or obligation incurred by or at the request of Tenant, within
the time and in the manner required by Section 7(f)(ii).

                    (v) Other Defaults. Tenant fails to perform, comply with, or observe any other
material agreement or obligation of Tenant under this Lease and the continuance of such failure
for a period of more than thirty (30) days after Landlord has delivered to Tenant written notice
thereof.

                    (vi) Insolvency. The filing of a petition by or against Tenant (the term “Tenant”
shall include, for the purpose of this Section 17(a)(vi) any guarantor of Tenant’s obligations
hereunder): (i) any bankruptcy or other insolvency proceeding; (ii) seeking any relief under any
state or federal debtor relief law; (iii) for the appointment of a liquidator or receiver for all
or substantially all of Tenant’s property or for Tenant’s interest in this Lease; (iv) for the
reorganization or modification of Tenant’s capital structure; or (v) any assignment for the
benefit of creditors

20

 

proceeding. Notwithstanding the foregoing, any such petition filed against Tenant shall not be an
Event of Default if Tenant causes such proceedings to be dismissed within ninety (90) days after
the filing thereof.

                    (vii) Occupancy. Tenant’s failure to continuously occupy the Premises and operate
its retail banking business therein.

               (b) Landlord Event of Default.

                    (i) Insurance. Landlord fails to procure, maintain and deliver to Tenant evidence of
the insurance policies and coverages as required under Section 10(b) and such failure shall
continue for five (5) Business Days after Tenant’s second written notice thereof to Landlord.

                    (ii) Other Defaults. Landlord fails to perform, comply with, or observe any other
material agreement or obligation of Landlord under this Lease and the continuance of such failure
for a period of more than thirty (30) days after Tenant has delivered to Landlord written notice
thereof.

                    (iii) Insolvency. The filing of a petition by or against Landlord (the term
“Landlord” shall include, for the purpose of this Section 17(b)(iii) any guarantor of Landlord’s
obligations hereunder): (i) any bankruptcy or other insolvency proceeding; (ii) seeking any relief
under any state or federal debtor relief law; (iii) for the appointment of a liquidator or
receiver for all or substantially all of Landlord’s property or for Landlord’s interest in this
Lease; (iv) for the reorganization or modification of Landlord’s capital structure; or (v) in any
assignment for the benefit of creditors proceeding, Notwithstanding the foregoing, any such
petition filed against Landlord shall not be an Event of Default if Landlord causes such
proceedings to be dismissed within ninety (90) days after the filing thereof.

               (c) Notice Periods. Any notice periods
provided for under this Section 17 shall run
concurrently with any statutory notice periods and any notice given hereunder may be given
simultaneously with or incorporated into any such statutory notice.

     18. Remedies.

               (a) Landlord’s Remedies. Upon any Tenant Event of Default, Landlord may, in addition to all
other rights and remedies afforded Landlord hereunder or by law or equity, take any one or more
of the following actions:

                    (i) Termination of Lease. Terminate this Lease by giving Tenant written notice
thereof, in which event Tenant shall immediately surrender possession of the Premises to Landlord
for Landlord’s account, and pay to Landlord the sum of: (A) all amounts due under Section 19(a);
and (B) all accrued Rent and other sums hereunder required to be paid through the date of
termination;

                    (ii) Termination
of Possession. Terminate Tenant’s right to possess the Premises
without terminating this Lease by giving written notice thereof to Tenant, in which event Tenant
shall immediately surrender possession of the Premises to Landlord for Tenant’s account and pay to
Landlord: (A) all Rent and other amounts accrued hereunder to the date of termination; (B) all
amounts due from time to time under Section 19(a); and (C) all Rent and other net sums required
hereunder to be paid by Tenant during the remainder of the Term, diminished by any net sums
thereafter received by Landlord through reletting the Premises during such period, after deducting
all costs incurred by Landlord in reletting the Premises. If Landlord elects to proceed under this
Section 18(a)(ii), Landlord may remove all of Tenant’s property from the Premises and store the
same in a public warehouse or elsewhere at the cost of, and for the account of, Tenant, without
becoming liable for any loss or damage which may be occasioned thereby. Landlord shall mitigate
Tenant’s liability under this Section 18(a)(ii) by using Landlord’s commercially reasonable best
efforts to promptly relet the Premises on such terms as Landlord in commercially reasonable
discretion may determine (including a term different from the Term, rental concessions, and
alterations to, and improvement of, the Premises). Notwithstanding the foregoing however, Landlord
shall not be obligated to: (I) relet the Premises before leasing other portions of the Building;
or (II) accept any prospective tenant proposed by Tenant unless such proposed tenant meets all of
Landlord’s commercially reasonable leasing criteria. Tenant shall not be entitled to the excess of
any consideration obtained by reletting over the Rent due hereunder. Unless Landlord delivers
written notice to Tenant expressly stating that it has elected to terminate this Lease, all
actions taken by Landlord to dispossess or exclude Tenant from the Premises shall be deemed to be
taken under this Section

21

 

18(a)(ii). If Landlord elects to proceed under this Section 18(a)(ii), Landlord may at any time
elect to terminate this Lease under Section 18(a)(i).

                    (iii) Perform Acts on Behalf of Tenant. Perform any act Tenant is obligated to perform
under the terms of this Lease and enter upon the Premises in connection therewith if necessary,
without being liable for any claim for damages therefor. Except in the case of an emergency (as
determined in the Landlord’s sole judgment), Landlord shall telephone or telefax Tenant prior to
entering the Premises. In all events, Tenant shall reimburse Landlord on demand for any expenses
which Landlord may incur in thus effecting compliance with Tenant’s obligations under this Lease
plus interest at the Default Rate.

               (b) Tenant’s Remedies. Upon any Landlord Event of Default or other breach by Landlord of its
obligations, covenants, agreements, representations or warranties hereunder, Tenant may, in
addition to all other rights and remedies afforded Landlord hereunder or by law or equity: (i)
enforce its indemnification rights under Section 11 hereof; and (ii) if Landlord fails to cure
any such Landlord Event of Default within thirty (30) days after Landlord’s receipt of written
notice thereof, or such longer period of time as may be necessary provided Landlord is diligently
attempting to cure, Tenant may terminate this Lease immediately upon Tenant’s payment to Landlord
all accrued Rent and other sums hereunder required to be paid through the date of termination.

     19. Payment by Parties; Non-Waiver; Cumulative Remedies.

               (a) Payment by Tenant. Upon any Tenant Event of Default, Tenant shall pay to Landlord all
costs incurred by Landlord (including court costs and reasonable attorneys’ fees and expenses)
in: (i) obtaining possession of the Premises; (ii) removing and storing Tenant’s or any other
occupant’s property; (iii) repairing, restoring, altering, remodeling, or otherwise putting the
Premises into condition acceptable to a new tenant; (iv) performing Tenant’s obligations that
Tenant failed to perform; (v) enforcing, or advising Landlord of, its rights, remedies, and
recourses arising out of the default; and (vi) other amounts due and owing under Section 11.

               (b) Payment by Landlord. Upon any Landlord Event of Default, Landlord shall pay to Tenant
all costs incurred by Tenant (including court costs and reasonable attorneys’ fees and expenses)
in: (i) performing Landlord’s obligations that Landlord failed to perform; (ii) enforcing its
rights, remedies, and recourses arising out of the default; and (iii) other amounts due and owing
under Section 11.

               (c) No Waiver. Landlord’s acceptance of Rent following an Event of Default shall not waive
Landlord’s rights regarding such Event of Default. No waiver by a Party of any violation or
breach of any of the terms contained herein shall waive such non-breaching Party’s rights
regarding any future violation of such term. Landlord’s acceptance of any partial payment of Rent
shall not waive Landlord’s rights with regard to the remaining portion of the Rent that is due,
regardless of any endorsement or other statement on any instrument delivered in payment of Rent
or any writing delivered in connection therewith; accordingly, Landlord’s acceptance of a partial
payment of Rent shall not constitute an accord and satisfaction of the full amount of the Rent
that is due.

               (d) Cumulative Remedies. Any and all remedies set forth in this Lease: (i) shall be in
addition to any and all other remedies Landlord may have at law or in equity, (ii) shall be
cumulative, and (iii) may be pursued successively or concurrently as Landlord may elect. The
exercise of any remedy by a Party shall not be deemed an election of remedies or preclude such
Party from exercising any other remedies in the future.

     20. Surrender of Premises.

               (a) Surrender. No act by Landlord shall be deemed an acceptance of a surrender of the
Premises, and no agreement to accept a surrender of the Premises shall be valid unless it is in
writing and signed by Landlord.

               (b) Delivery of Premises to Landlord. At the expiration or termination of this Lease,
Tenant: (i) shall deliver to Landlord the Premises with all improvements located therein in good
repair and condition, free of Hazardous Materials placed on the Premises during the Term,
broom-clean, reasonable wear and tear (and condemnation and Casualty damage not caused by Tenant,
as to which Sections 14 and 15 shall control) excepted; (ii) deliver to Landlord all keys to the
Premises; (iii) may remove all unattached trade fixtures, furniture, and personal property placed
in the Premises or elsewhere in the Building by Tenant if Tenant has performed all of Tenant’s
obligations hereunder; (iv) may not remove any such trade fixtures, furniture, or personal
property in the

22

 

Premises that was paid for, in whole or in part, by Landlord or any wiring or cabling unless
Landlord requires such removal; (iv) shall, at Landlord’s option, remove such alterations,
additions, improvements, trade fixtures, personal property, equipment, wiring, conduits, cabling,
and furniture, including Tenant’s Off-Premises Equipment, as Landlord may reasonably request;
provided, however, that Tenant shall not be required to remove any such addition or
improvement to the Premises or the Project if Landlord has specifically agreed in writing that the
improvement or addition in question need not be removed; (v) shall repair all damage caused by
such removal; (vi) at Landlord’s reasonable option, shall be deemed to have abandoned all items
not so removed, which items may be appropriated, sold, stored, destroyed or otherwise disposed
of by Landlord without notice to Tenant and without any obligation to account for such items; any
such disposition shall not be considered a strict foreclosure or other exercise of Landlord’s
rights. The provisions of this Section 20 shall survive the end of the Term.

     21. Holding
Over. If Tenant fails to vacate the Premises at the end of the Term,
Tenant shall be a tenant at sufferance and, in addition to all other Losses and remedies to which
Landlord may be entitled for such holding over; (a) Tenant shall pay, in addition to the other
Rent, Basic Rent equal to 125% of the Rent payable during the last month of the Term, for each
day of holdover, and (b) Tenant shall otherwise continue to be subject to all of Tenant’s
obligations under this Lease. The provisions of this Section 21 shall not be deemed to limit or
constitute a waiver of any of Landlord’s other rights or remedies provided herein or at law. If
Tenant fails to surrender the Premises upon the termination or expiration of this Lease, in
addition to any other liabilities to Landlord accruing therefrom, Tenant shall protect, defend,
indemnify and hold Landlord harmless from all loss, costs (including reasonable attorneys’ fees)
and liability resulting from such failure, including any claims made by any succeeding tenant
founded upon such failure to surrender, and any lost profits to Landlord resulting therefrom.

     22. Certain Rights Reserved by Landlord. Provided that the exercise of such
rights does not unreasonably interfere with Tenant’s occupancy of the Premises, Landlord shall
have the following rights:

               (a) Building Operations. Landlord may: (i) decorate and make inspections, repairs,
alterations, additions, changes, or improvements, whether structural or otherwise, in and about
the Project, or any part thereof; (ii) enter upon the Premises after giving Tenant reasonable
written notice thereof, except in cases of real or apparent emergency, in which case no notice
shall be required; (iii) during the continuance of any such work, temporarily close doors,
entryways, public space, and corridors in the Building and/or interrupt or temporarily suspend
Building services and facilities; (iv) change the arrangement and location of entrances or
passageways, doors, and doorways, corridors, elevators, stairs, restrooms or other public parts
of the Building;

               (b) Security. To take such reasonable measures as Landlord deems advisable for the security
of the Building and its occupants including: (i) evacuating the Building for cause, suspected
cause or for drill purposes; (ii) temporarily denying access to the Building; and (iii) closing
the Building after normal business hours and on Sundays and Holidays, subject, however,
to Tenant’s right to enter when the Building is closed after normal business hours under such
reasonable regulations as Landlord may prescribe from time to time;

               (c) Prospective Purchasers and Lenders. To enter the Premises at all reasonable hours to
show the Premises to prospective purchasers or lenders; and

               (d) Prospective Tenants. At any time during the last twelve (12) months of the Term (or
earlier if Tenant has notified Landlord in writing that it does not desire to renew the Term) or
at any time following the occurrence of an Event of Default, to enter the Premises at all
reasonable hours to show the Premises to prospective tenants.

     23. Miscellaneous.

               (a) Landlord Transfer. Landlord may transfer any portion of the Project and any of its
rights under this Lease. If Landlord assigns its rights under this Lease, then Landlord shall
thereby be released from any further obligations hereunder arising after the date of transfer,
provided that the assignee assumes in writing Landlord’s obligations hereunder arising from and
after the transfer date.

               (b) Force Majeure. Whenever a period of time is herein prescribed for action to be taken by
either Party. hereto, such Party shall not be liable or responsible for, and there shall be
excluded from the computation of any such period of time, any delays due to strikes, riots, acts
of God, shortages of labor or materials, war, terrorist acts or

23

 

activities, governmental laws, regulations, or restrictions, or any other causes of any kind
whatsoever which are beyond the control of such Party.

               (c) Brokerage. Except as previously disclosed in writing by Tenant to Landlord, Tenant is not
represented by any broker or agent in connection with the negotiation or execution of this Lease.
Any broker so disclosed to Landlord by Tenant shall be compensated, if at all, as provided in a
written agreement between Landlord and such broker. Tenant and Landlord shall each indemnify the
other against all costs, expenses, attorneys’ fees, liens and other liability for commissions or
other compensation claimed by any other broker or agent claiming the same by, through, or under
the Indemnifying Party.

               (d) Estoppel Certificates. From time to time, Tenant shall furnish to any Person designated by
Landlord, within ten (10) days after Landlord has made a request therefor, a certificate signed by
Tenant confirming and containing such factual certifications and representations as to this Lease
as Landlord may reasonably request. Unless otherwise required by Landlord’s Mortgagee or a
prospective purchaser or mortgagee of the Project, the initial form of estoppel certificate to be
signed by Tenant is attached hereto as Exhibit F. If Tenant does not deliver to Landlord
the certificate signed by Tenant within such required time period,
Landlord, Landlord’s Mortgagee
and any prospective purchaser or mortgagee, may conclusively presume and rely upon the following
facts: (i) this Lease is in full force and effect; (ii) the terms and provisions of this Lease have
not been changed except as otherwise represented by Landlord; (iii) not more than one monthly
installment of Basic Rent and other charges have been paid in advance; (iv) there are no claims
against Landlord nor any defenses or rights of offset against collection of Rent or other charges;
and (v) Landlord is not in default under this Lease. In such event, Tenant shall be estopped from
denying the truth of the presumed facts.

               (e) Notices. All notices and other communications given pursuant to this Lease shall be in
writing and shall be: (i) hand-delivered to the intended addressee at the address specified in the
Basic Lease Information; (ii) sent by a nationally recognized overnight courier service to the
address specified in the Basic Lease Information; or (iii) sent by facsimile transmission during
normal business hours followed by a confirmatory letter sent in another manner permitted
hereunder. All notices shall be effective upon delivery to the address of the addressee. The
Parties hereto may change their addresses by giving notice thereof to the other in conformity with
this provision.

               (f) Separability. If any clause or provision of this Lease is illegal, invalid, or
unenforceable under present or future laws, then the remainder of this Lease shall not be affected
thereby and in lieu of such clause or provision, there shall be added as a part of this Lease a
clause or provision as similar in terms to such illegal, invalid, or unenforceable clause or
provision as may be possible and be legal, valid, and enforceable.

               (g) Amendments; Binding Effect; No Electronic Records. This Lease may not be amended except by
instrument in writing signed by Landlord and Tenant. No provision of this Lease shall be deemed to
have been waived by a Party unless such waiver is in writing signed by such waiving Party, and no
custom or practice which may evolve between the Parties in the administration of the terms hereof
shall waive or diminish the right of either Party to insist upon the performance by the other Party
in strict accordance with the terms hereof. Landlord and Tenant hereby agree not to conduct the
transactions or communications contemplated by this Lease by electronic means, except by facsimile
transmission as specifically set forth in Section 23(e) and email under Section 6(b); nor shall the
use of the phrase “in writing” or the word “written” be construed to include electronic
communications except by facsimile transmissions as specifically set forth in Section 23(e) and
email under Section 6(b). The terms and conditions contained in this Lease shall inure to the
benefit of and be binding upon the Parties, and upon their respective successors in interest and
legal representatives, except as otherwise herein expressly provided. This Lease is for the sole
benefit of Landlord and Tenant, and, other than Landlord’s Mortgagee, no third party shall be
deemed a third party beneficiary hereof.

               (h) Quiet Enjoyment. Provided Tenant has performed all of its obligations hereunder, Tenant
shall peaceably and quietly hold and enjoy the Premises for the Term, without hindrance from
Landlord or any Person claiming by, through, or under Landlord, but not otherwise, subject to the
terms and conditions of this Lease.

               (i) No Merger. There shall be no merger of the leasehold estate hereby created with the fee
estate in the Premises or any part thereof if the same Person acquires or holds, directly or
indirectly, this Lease or any interest in this Lease and the fee estate in the leasehold Premises
or any interest in such fee estate.

24

 

     (j) No Offer. The submission of this Lease to Tenant shall not be construed as an
offer, and Tenant shall not have any rights under this Lease unless Landlord executes a copy
of this Lease and delivers it to Tenant.

     (k) Entire Agreement. This Lease constitutes the entire agreement between Landlord and
Tenant regarding the subject matter hereof and supersedes all oral statements and prior
writings relating thereto. Except for those set forth in this Lease, no representations,
warranties, or agreements have been made by Landlord or Tenant to the other with respect to
this Lease or the obligations of Landlord or Tenant in connection
therewith. The normal rule
of construction that any ambiguities be resolved against the drafting Party shall not apply to
the interpretation of this Lease or any exhibits or amendments hereto.

     (l) Waiver
of Jury Trial. To the maximum extent permitted by Applicable Law,
Landlord and Tenant each waive any right to trial by jury in any Litigation or to have a
jury participate in resolving any Dispute arising out of or with respect to this Lease or any other instrument,
document or agreement executed or delivered in connection herewith or the transactions related
hereto.

     (m) Governing Law; Venue. This Lease shall be deemed to have been executed and delivered
in the State of Florida and will be governed by and construed in accordance with the internal law
of the State of Florida, excluding any conflicts or choice of law, rule or principle that might
otherwise refer construction or interpretation of this Lease to the substantive law of another
jurisdiction. Each Party shall bring any Action that relates to any Claim arising out of or
related to this Lease exclusively in the United States District Court for the Middle District of
Florida or a Florida state court of competent jurisdiction and solely in connection with Claims
arising under this Lease or the transactions contained in or contemplated by this Lease: (i)
irrevocably submits to the exclusive jurisdiction of such chosen courts; (ii) waives any objection
to laying venue in any such action or proceeding in such chosen courts; (iii) to the fullest
extent permitted by Applicable Law, waives any objection that such chosen courts are an
inconvenient forum or do not have jurisdiction over any Party; and (iv) agrees that service of
process upon  such Party in any such action or proceeding will be effective if notice is given in
accordance with Section 23(e).

     (n) Recording. Tenant shall not record this Lease or any memorandum of this Lease without the
prior written consent of Landlord, which consent may be withheld or denied in the sole and
absolute discretion of Landlord, and any recordation by Tenant shall be a material breach of
this Lease. Tenant grants to Landlord a  power of attorney to execute and record a release
releasing any such recorded instrument of record that was recorded without the prior written
consent of Landlord.

     (o) Joint and Several Liability. If Tenant is comprised of more than one Person, each
such Person shall be jointly and severally liable for Tenant’s obligations under this Lease.
All unperformed obligations of a Party hereunder not fully performed at the end of the Term
shall survive the end of the Term, including Tenant’s payment obligations with respect to Rent
and all obligations concerning the condition and repair of the Premises.

     (p) Financial Reports. Within fifteen (15) days after Landlord’s request, Tenant will
furnish Tenant’s most recent thrift financial report, or equivalent call report or financial
report, submitted by Tenant to the applicable regulatory authority If Tenant is a publicly
traded corporation, Tenant may satisfy its obligations hereunder by providing to Landlord
Tenant’s most recent annual and quarterly reports. Tenant will discuss its financial reports
with Landlord and, following the occurrence of an Event of Default hereunder, will give
Landlord access to Tenant’s books and records in order to enable Landlord to verify the
financial statements. Landlord shall treat all such financial information as Confidential
Information in accordance with the provisions of Section 23(s). Landlord will not disclose any
aspect of Tenant’s financial reports that Tenant designates to Landlord as confidential except
as permitted by Section 23(s) and to: (i) Landlord’s Mortgagee or prospective mortgagees or
purchasers of the Building; (ii) in Litigation between Landlord and Tenant; and/or (iii) if
required by court order. Tenant shall not be required to deliver the financial reports required
under this Section 23(p) more than once in any twelve (12)-month period unless requested by
Landlord’s Mortgagee or a prospective buyer or lender of the Building or an Event of Default
occurs.

     (q) Landlord’s Fees. Whenever Tenant requests Landlord to take any action not required of
it hereunder or give any consent required or permitted under this Lease, Tenant will reimburse
Landlord for Landlord’s reasonable, out-of-pocket costs payable to third Persons and incurred
by Landlord in reviewing the proposed action or consent,  including reasonable
attorneys’, engineers’ or architects’ fees, within thirty (30) days
after Landlord’s

25

 

delivery to Tenant of a statement of such costs. Tenant will be obligated to make such
reimbursement without regard to whether Landlord consents to any such proposed action.

     (r) Telecommunications. Tenant and its telecommunications companies, including local exchange
telecommunications companies and alternative access vendor services companies, shall have no right
of access to and within the Building, for the installation and operation of Telecommunications
Services, for part or all of Tenant’s telecommunications within the Building and from the Building
to any other location without Landlord’s prior written consent. All providers of
Telecommunications Services shall be required to comply with the rules and regulations of the
Building, Applicable Laws and Landlord’s policies and practices for the Building. Tenant
acknowledges that Landlord shall not be required to provide or arrange for any Telecommunications
Services and that Landlord shall have no liability to any Tenant Party in connection with the
installation, operation or maintenance of Telecommunications Services or any equipment or
facilities relating thereto. Tenant, at its cost and for its own account, shall be solely
responsible for obtaining all Telecommunications Services.

     (s) Confidentiality.

          (i) In General. Neither Party shall make use of, disseminate or in any way disclose
any Confidential Information of the other Party or its Affiliates, except: (A) as necessary to
perform its obligations hereunder; (B) as may be required by Applicable Law; or (C) with the
express written authorization of the Disclosing Party. Each Party shall keep Confidential
Information confidential and ensure that its Affiliates, employees, agents, and Representatives
who have access to such Confidential Information comply with this non-disclosure obligation. If a
Party contracts with any agents or independent contractors to perform certain of its obligations
hereunder, such Party shall enter into a confidentiality agreement with such Person under which
such Person and its employees, agents and Representatives are restricted from disclosing, using or
duplicating such Confidential Information, except in a manner
consistent with this Section 23(s).
The Parties shall maintain appropriate physical, electronic, technical, and procedural safeguards
to receive, store, dispose of (if applicable), and secure all Confidential Information to protect
it from unauthorized access, use, disclosure, alteration, loss, and destruction, and to protect
against any anticipated threats or hazards to the security or integrity of such records or
information which could result in substantial harm or inconvenience to any Customer. The
safeguards used by each Receiving Party to protect Confidential Information of the Disclosing
Party shall be no less than those used by the Receiving Party to protect its own Confidential
Information. Such safeguards and standards shall be commercially reasonable, in keeping with
generally accepted standards in the financial services industry and consistent with Applicable
Law. The Receiving Party shall notify the Disclosing Party if at any time during the term of this
Agreement the notifying Party intends to materially modify its physical, electronic, technical,
and procedural safeguards or standards.

          (ii) This Lease. The Parties shall keep the terms of this Agreement strictly
confidential and take all precautions necessary to prevent this Agreement or any portion of this
Agreement from being disclosed or made available to any other Person, in any form or medium,
without the written consent of the other Party. Notwithstanding the forgoing, a Party may share
this Agreement with: (A) such Party’s Affiliates, to the extent necessary to assist a Party with
its obligations hereunder; (B) such Party’s officers, directors, employees, auditors, accountants,
attorneys and other Representatives; (C) such Party’s, examiners, regulatory and governmental
agencies and other governmental regulatory agencies that may have examination, enforcement or
other jurisdiction over such Party, including, but not limited to, the OTS; (D) such Party’s
insurers and ratings agencies; (E) Landlord’s Mortgagee or prospective mortgagees or purchasers of
the Building; (F) due diligence personnel in connection with a
due diligence review of a Party; (G) any vendor, agent or contractor, to the extent necessary for such Person’s performance of any
obligations hereunder; and (H) any other Person as may be required by Applicable Law. A Party
shall cause each such Person to whom such Party has provided a copy of this Agreement (other than
such Party’s governmental regulatory or examination authority) to enter into a signed writing
binding such Person to the confidentiality provisions herein.

     (t) Notice Concerning Radon Gas. Radon is a naturally occurring radioactive gas that, when it
has accumulated in a structure in sufficient quantities, may present health risks to persons who
are exposed to it. Levels of radon that exceed Federal and State guidelines have been found in
buildings in the State of Florida. Additional information regarding radon and radon testing may be
obtained from the county public health unit. Landlord makes no representation to Tenant concerning
the presence or absence of radon gas in the Premises or the Building at any time or in any
quantity. By executing this Lease, Tenant expressly releases Landlord from any loss, claim,
liability,

26

 

or damage now or hereafter arising from or relating to the presence at any time of such substances
in the Premises or the Building.

     (u) No
Liability for Crimes. Landlord makes no representations or warranties with respect to
crime in the area, undertakes no duty to protect against criminal acts and shall not be liable for
any injury, wrongful death or property damage arising from any criminal acts. Landlord may, from
time to time, employ security personnel and equipment, however, such personnel and equipment are
only for the protection of Landlord’s property. Landlord reserves the right, in its sole
discretion, to start, alter or terminate any such security services without notice. Tenant is urged
to provide security for its invitees, its own personnel, and property as it deems necessary. Tenant
is urged to obtain insurance to protect against criminal acts.

     (v) Authority (i) Tenant hereby represents and warrants to Landlord that: (A) Tenant is a
duly formed and existing federal savings association organized under the laws of the United States
of America; (B) Tenant is duly qualified to do business in the state in which the Premises are
located; (C) Tenant has full right and authority to execute and deliver this Lease; (D) each Person
signing on behalf of Tenant is authorized to do so. (ii) Landlord hereby represents and warrants to
Tenant that: (A) Landlord is a duly formed and existing Limited Partnership organized under the
laws of the state of Florida; (B) Landlord is qualified to do business in the state in which the
Premises are located; (C) Landlord has full right and authority to execute and deliver this Lease;
and (D) each Person signing on behalf of Landlord is authorized to do so.

     (w) Hazardous Materials. Neither Party shall use, generate, store, or dispose of, or permit
the use, generation, storage or disposal of Hazardous Materials on or about the Premises or the
Project except in a manner and quantity necessary for the ordinary performance of such Party’s
business, and then in compliance with all Applicable Laws. If a Party breaches its obligations
under this Section 23(w), the non-breaching Party may immediately take any and all action
reasonably appropriate to remedy the same, including taking all appropriate action to clean up or
remediate any contamination resulting from the breaching Party’s use, generation, storage or
disposal of Hazardous Materials. A Party’s breach of its
obligations under this Section 23(w)
shall be subject to the indemnification provisions of
Section 11.

	(x)	 	Interpretation.

          (i) Headings. The table of contents and headings contained in this Lease are for
reference purposes only and do not limit or otherwise affect any of the provisions of this Lease.

          (ii) Use of Specified terms. Whenever the words “include”, “includes” or “including”
are used in this Lease, they will be deemed to be followed by the words “but not limited to.” Any
singular term in this Lease will be deemed to include the plural, and any plural term the singular.
All pronouns and variations of pronouns will be deemed to refer to the feminine, masculine or
neuter, singular or plural, as the identity of the Person referred to may require.

          (iii) Reference to Entire Lease. Whenever the words “herein” or “hereunder” are used
in this Lease, they will be deemed to refer to this Lease as a whole and not to any specific
Section.

          (iv) United States Dollars. Whenever a dollar figure ($) is used in this Lease, it
will mean United States dollars.

          (v) No Drafting Inference. The Parties acknowledge that they have each been
represented by counsel in the negotiation and preparation of this Lease and that no provision of
this Lease should be deemed to have been drafted solely by counsel for any particular Party.

          (vi) Basic Lease Information. The definitions and basic provisions set forth in the
Basic Lease Information are incorporated herein by reference for all purposes.

	(y)	 	List of Exhibits. All exhibits and attachments attached hereto are incorporated herein by
this reference.

Exhibit A —  Outline of Premises

Exhibit B — Description of the Land

27

 

Exhibit C —  Rules and Regulations

Exhibit D — Tenant Finish-Work

Exhibit E — Form of Confirmation of Commencement Date Letter

Exhibit F — Form of Tenant Estoppel Certificate

Exhibit G — Parking

Exhibit H — Renewal Option

Exhibit I — Intentionally deleted

Exhibit J — Signage

Exhibit K — Operating Costs

     24. Representations
and Warranties. Tenant hereby represents and warrants that:

          (a) Tenant is not designated as an individual or entity that has been determined to have
committed, or poses a significant risk of committing, acts of terrorism that threaten the security
of the U.S. nationals or the national security, foreign policy, or economy of the U.S., which
would violate the Executive Order 13224, entitled “Blocking Property and Prohibiting Transactions
with Persons Who Commit, Threaten to Commit, or Support Terrorism,” which became effective on
September 24, 2001 (the “Order”); and

          (b) Tenant is not owned or controlled by, or acting on behalf of an individual or entity
which would violate the Order, and

          (c)
Tenant has not and will never assist in, sponsor, or provide financial, material, or
technological support for, or financial or other services to or in support of, acts of terrorism
or individuals or entities designated in or under the Order; and

          (d) Tenant is not otherwise associated with certain individuals or entities designated in or
under the Order,

          This Lease is executed on the respective dates set forth below, but for reference purposes,
this Lease shall be dated as of the date first above written. If the execution date is left blank,
this Lease shall be deemed executed as of the date first written above.

	 	 	 	 	 

	TWO WITNESSES:
	 
	 	 	 	 
	 	 	 
	(Print Name)
	 	 	 	 
	 

	 	 

	 	 
	 
	 	 	 	 
	 
	 	 	 	 
	 
	 	 	 	 
	 	 	 
	(Print Name)
	 	 	 	 
	 

	 	 

	 	 
	 
	 	 	 	 
	 
	 	 
	 
	 	 
	 
	 	 
	 
	 	 
	 
	 	 
	 
	 	 
	 
	 	 
	 
	 	 
	 	 	 
	(Print Name)
	 	 	 	 
	 

	 	 

	 	 
	 
	 	 	 	 
	 	 	 
	(Print Name)
	 	 	 	 
	 

	 	 

	 	 

	 	 	 	 	 	 	 

	LANDLORD:
	 
	 	 	 	 	 	 
	RIVERSIDE AVENUE PARTNERS, LTD.
	 
	 	 	 	 	 	 
	By:	 	RAP Property Management, LLC, as its

General Partner	 	 
	 
	 	 	 	 	 	 
	 

	 	By:	 	 	 	 
	 

	 	Name:	 	 	 	 
	 

	 	Title:	 	 	 	 
	 

	 	Execution Date:	 	 	 	 
	 
	 	 	 	 	 	 

	 	 	 	 	 

	TENANT:	 	 
	 
	 	 	 	 
	EVERBANK a federal savings bank
	 
	 	 	 	 
	By:
	 	/s/ W. Blake Wilson	 	 
	Name:

	 	W. Blake Wilson	 	 
	Title:

	 	President	 	 
	Execution Date:
	 	 	 	 

28

 

EXHIBIT A

OUTLINE
OF PREMISES

A-1

 

 

 

EXHIBIT B

DESCRIPTION
OF THE LAND

B-1

 

EXHIBIT B

Fee Parcel:

A portion of Lot 1, Block 1, Supplemental Plat to Riverside, according to the Plat thereof recorded
in Deed Book “Q”, page 434 of the former public records of Duval County, Florida; A portion of Lots
1 and 2, Block 1, Riverside, according to the Plat thereof recorded in Plat Book 1, page 109, said
former public records; together with all or portions of Lots 1, 2, 3, 4 and 5, Pipes Replat of Lot
1, Block 1, Supplemental Plat to Riverside, according to the plat thereof recorded in Plat Book 6,
page 39 of the current public records of said Duval County, Florida, being more particularly
described as follows:

For a point of reference, commence at the intersection of the former Northerly right of way line
of Rosselle Street, an 80 foot right of way per said Plat of Riverside (closed by City Ordinance
92-1597-945), with the former Easterly right of way line of Riverside Avenue (State Road No. 211),
an 80 foot right of way as formerly established; thence South 67°38’09” East, departing said
former right of way line, 20.00 feet to the intersection of said former Northerly right of way
line of Rosselle Street, with the current Easterly right of way line of Riverside Avenue, a 100
foot right of way as presently established; thence North 22°15’06” East, along said current
Easterly right of way line, 406.50 feet to the point of beginning.

From said point of beginning, thence continue along said current Easterly right of way line the
following three (3) courses: 1) North 22°15’06” East, 312.25 feet: 2) North 24°54’49” East, 88.80
feet; 3) North 33°19’47” East, 35.53 feet to a point lying on the Southerly right of way line of
Forest Street, a 25 foot right of way as presently established; thence South 45°39’09” East,
departing said Easterly right of way line of Riverside Avenue, along said Southerly right of way
line, 214.41 feet; thence South 22°10’33” West, departing said Southerly right of way line, 150.36
feet; thence South 30°48’24” West, 44.50 feet; thence South 22°10’33” West, 160.54 feet; thence
North 67°49’27” West, 203.40 feet to the point of beginning.

Easement Parcel:

Together with easement rights as set forth in that certain Grant of Easement recorded in
Official Records Book 12211, page 1091, of the current public records of Duval County,
Florida.

 

 

EXHIBIT C

RULES AND REGULATIONS

     The following rules and regulations (“Rules and Regulations”) govern the use of the
Premises and the Project. Tenant will be bound by such Rules and Regulations and shall to cause
its employees, subtenants, assignees, contractors, suppliers, customers and invitees to observe
the same.

     1. Sidewalks, doorways, vestibules, halls, stairways, and other similar areas shall not be
obstructed by tenants or used by any tenant for purposes other than ingress and egress to and
from their respective leased premises and for going from one to another part of the Building.

     2. Plumbing, fixtures and appliances shall be used only for the purposes for which designed,
and no sweepings, rubbish, rags or other unsuitable material shall be thrown or deposited
therein. Damage resulting to any such fixtures or appliances from misuse by a tenant or its
agents, employees or invitees, shall be paid by such tenant.

     3. No signs, advertisements or notices shall be painted or affixed on or to any windows or
doors or other part of the Building without the prior written consent of Landlord. No nails, hooks
or screws (other than those which are necessary to hang paintings, prints, pictures, or other
similar items on the Premises’ interior walls) shall be driven or inserted in any part of the
Building except by Building maintenance personnel. Landlord will have the right to remove, at
Tenant’s expense and without notice, any sign installed or displayed in violation of this rule.
Tenant agrees not to place anything against or near glass partitions or doors or windows which
may appear unsightly from outside the Premises, including without limitation, window treatments,
blinds, screens, foil shades, tinting materials or stickers.

     4. Landlord shall provide and maintain an alphabetical directory for all tenants in the main
lobby of the Building.

     5. Landlord shall provide all door locks in each tenant’s leased premises, at the cost of
such tenant. Tenant shall not alter any lock or install any new or additional lock or bolt on any
door of the Premises without Landlord’s prior written consent. Landlord shall furnish to each
tenant a reasonable number of keys to such tenant’s leased premises, at such tenant’s cost, and no
tenant shall make a duplicate thereof.

     6. Movement in or out of the Building of furniture or office equipment, or dispatch or
receipt by tenants of any bulky material, merchandise or materials which require use of elevators
or stairways, or movement through the Building entrances or lobby shall be conducted via the
Building’s freight elevator and may be subject to Landlord’s supervision and may be limited or
regulated by Landlord in its sole discretion. Each tenant assumes all risks of and shall be liable
for all damage to articles moved and injury to persons or public engaged or not engaged in such
movement, including equipment, property and personnel of Landlord if damaged or injured as a
result of acts in connection with carrying out this service for such tenant.

     7. Landlord may prescribe weight limitations and determine the locations for safes and other
heavy equipment or items, which shall in all cases be placed in the Premises so as to distribute
weight in a manner acceptable to Landlord which may include the use of such supporting devices as Landlord may
require. All damages to the Building caused by the installation or removal of any property of a tenant, or
done by a tenant’s property while in the Building, shall be repaired at the expense of such tenant.

     8. Corridor doors, when not in use, shall be kept closed. Nothing shall be swept or thrown
into the corridors, halls, elevator shafts or stairways. No birds or animals (other than seeing-eye dogs)
shall be brought into or kept in, on or about the Premises. No portion of the Premises shall at
any time be used or occupied as sleeping or lodging quarters.

     9. Tenant shall cooperate with Landlord’s employees in keeping the Premises neat and clean.
Tenant shall not employ any person for the purpose of such cleaning other than the Building’s cleaning
and maintenance personnel.

C-1

 

     10. To ensure orderly operation of the Building, no ice, mineral or other water, towels,
newspapers, etc. shall be delivered to any leased area except by persons approved by Landlord,
which approval will not be unreasonably delayed or withheld.

     11. Tenant shall not permit or allow the Premises to be occupied or used in a manner
offensive or objectionable to Landlord or other occupants of the Building by reason of noise,
odors or vibrations, intense light, heat or other form of electromagnetic radiation or otherwise
interfere in any way with other tenants or persons having business with them.

     12. No machinery of any kind (other than normal office equipment) shall be operated by any
tenant on its leased area without Landlord’s prior written consent, nor shall any tenant use or
keep in the Building any flammable or explosive fluid or substance (other than typical office
supplies [e.g., photocopier toner] used in compliance with all Laws).

     13. Landlord will not be responsible for lost or stolen personal property, money or jewelry
from the project regardless of whether such loss occurs when the area is locked against entry or
not.

     14. Tenant will not sell, or permit the sale at retail of newspapers, magazines, periodicals,
theater tickets or any other goods or merchandise to other tenants or to the general public in or
on the Project. No vending or dispensing machines of any kind may be maintained in any leased
premises without the prior written permission of Landlord.

     15. Tenant shall not conduct any activity on or about the Project which will draw pickets,
demonstrators, or the like.

     16. All vehicles are to be currently licensed, in good operating condition, parked for
business purposes having to do with Tenant’s business operated in the Premises, parked within
designated parking spaces, one vehicle to each space. No vehicle shall be parked as a “billboard”
vehicle in the parking lot. Any vehicle parked improperly may be towed away. Tenant, Tenant’s
agents, employees, vendors and customers who do not operate or park their vehicles as required
shall subject the vehicle to being towed at the expense of the owner or driver. Landlord may place
a “boot” on the vehicle to immobilize it and may levy a charge of $50.00 to remove the “boot.”
Tenant shall indemnify, hold and save harmless Landlord of any liability arising from the towing
or booting of any vehicles belonging to a Tenant Party.

     17. All directional signs, arrows and posted regulations must be observed at all times.

     18. Landlord reserves the right from time to time to modify and/or adopt such other
reasonable and non-discriminatory rules and regulations for the parking facilities as it deems
reasonably necessary for the operation of the parking facilities.

     19. No tenant may enter into phone rooms, electrical rooms, mechanical rooms, roof or other
service areas of the Building unless accompanied by Landlord or the Building manager.

     20. Tenant will not permit any Tenant Party to bring onto the Project any handgun, firearm or
other weapons of any kind or illegal drugs.

     21. Landlord will in all cases retain the right to control and prevent access thereto by any
persons whose presence in the reasonable judgment of Landlord would be prejudicial to the safety,
character, reputation and interest of the Project and its tenants, provided that nothing herein
contained will be construed to prevent such access to persons with whom any tenant normally deals
in the ordinary course of its business, unless such persons are engaged in illegal or unlawful
activities.

     22. Tenant agrees to comply with all safety, fire protection and evacuation procedures and
regulations established by Landlord or any governmental agency.

C-2

 

     23. Tenant shall not permit its employees, invitees or guests to smoke in the Premises or the
lobbies, passages, corridors, elevators, vending rooms, rest rooms, stairways or any other area
shared in common with other tenants in the Building, or permit its employees, invitees, or guests
to loiter at the Building entrances for the purposes of smoking. Landlord may, but shall not be
required to, designate an area for smoking outside the Building.

     24. These Rules and Regulations are in addition to, and will not be construed to in any way
modify or amend, in whole or in part, the terms, covenants, agreements and conditions of the Lease.
Landlord may waive any one or more of these Rules and Regulations for the benefit of Tenant or any
other tenant, but no such waiver by Landlord will be construed to be a waiver of such Rules and
Regulations in favor of Tenant or any other tenant, nor prevent Landlord from thereafter enforcing
any such Rules and Regulations against any or all of the tenants of the Project.

     25. Landlord reserves the right to make such other and reasonable and nondiscriminatory Rules
and Regulations as, in its judgment, may from time to time be needed for safety and security, for
care and cleanliness of the Project and for the preservation of good order therein. Tenant agrees
to abide by all such Rules and Regulations hereinabove stated and any additional reasonable and
non-discriminatory rules and regulations which are adopted. Tenant is responsible for the
observance of all of the foregoing rules by Tenant’s employees, agents, clients, customers,
invitees and guests.

C-3

 

EXHIBIT D

WORK LETTER

(Tenant Construction)

     This Work Letter sets forth the terms and conditions relating to the construction of the
Leasehold Improvements. The parties acknowledge that the Building is under construction. Landlord
shall be obligated to construct the Building in accordance with the plans and specifications
prepared by Landlord’s architect.

ARTICLE 1

DEFINITIONS

     1.01 “Approved Construction Drawings” means the Construction Drawings approved by Landlord and
Tenant pursuant to the process set forth in Article 2 below.

     1.02 “Approved Space Plan” means the Space Plan approved by Landlord and Tenant pursuant to
the process set forth in Article 2 below.

     1.03 “Architect” means Reynolds Smith & Hills, Inc.

     1.04 “Change Order” means any change, modification or addition to the Approved Construction
Drawings.

     1.05 “Construction Drawings” means: (a) detailed architectural drawings and specifications for
the Leasehold Improvements, including without limitation, partition plan, demolition plan,
reflected ceiling plan, power, communication and telephone plan, electrical outlets, finish plan,
elevations, details and sections; and (b) mechanical, electrical, plumbing and lighting plans and
specifications where necessary for installation to Building systems.

     1.06 “Contractor” means the contractor selected by Landlord under Section 3.01.

     1.07 “Landlord’s Representative” means Paul Lunetta, who Landlord has designated as its sole
representative with respect to the matters set forth in this Work Letter, and who, until further
notice to Tenant, has full authority and responsibility to act on behalf of Landlord as required in
this Work Letter.

     1.08 “Landlord’s Work” means the work to be provided by Landlord hereunder.

     1.09 “Leasehold Improvements” means the aggregate of the Landlord’s Work and Tenant’s Work.

     1.10 “Rentable Area of Premises” means the number of rentable square feet in the Premises, as
specified in the Lease.

     1.11 “Space Plan” means a first draft of the Leasehold Improvements as understood by the
Architect after consulting with Tenant’s Representative and others as appropriate.

     1.12 “Space Planning Allowance” is included within the Tenant Improvement Allowance and shall
be for space planning, architectural and engineering fees.

     1.13 “Tenant Improvement Allowance” means the allowance of $15.00 per square foot of rentable
square feet in the Premises, to be provided by Landlord as set forth herein.

     1.14 “Tenant’s Representative” means John Surface, who Tenant has designated as its sole
representative with respect to the matters set forth in this Work Letter, and who, until further
notice to Landlord, has full authority and responsibility to act on behalf of Tenant as required in
this Work Letter. Tenant’s Representative

D-1

 

is authorized to execute and deliver any and all documents required by this Work Letter. Tenant
hereby warrants and represents to Landlord that Tenant’s Representative has all of the requisite
power and authority to execute and deliver such documents and that Tenant shall be bound by the
execution of such documents by Tenant’s Representative.

     1.15 “Tenant’s Work” means all items which are supplied, constructed, installed and
finished by Tenant, as provided in this Work Letter.

ARTICLE 2

DEVELOPMENT OF CONSTRUCTION DRAWINGS

     2.01 Space Plan. The Architect has been retained by Tenant to prepare its Space Plan. Tenant
shall cause Architect to submit the Space Plan to Landlord for Landlord’s review and approval.
Within five (5) Business Days after Landlord receives the Space Plan, Landlord shall, in its sole
but reasonable discretion, approve or disapprove the Space Plan. If Landlord disapproves the Space
Plan, Landlord shall return the Space Plan to Tenant, along with a statement setting forth the
grounds for the disapproval. In such event, Tenant shall make such changes as are necessary in
order to make the Space Plan acceptable to Landlord and shall re-submit the revised Space Plan to
Landlord. This procedure shall be repeated until Landlord and Tenant have approved the Space Plan.
When approved by Landlord and Tenant, the Space Plan shall be deemed to be the Approved Space
Plan. The costs of preparation of the Approved Space Plan shall be paid out of the Tenant
Improvement Allowance.

     2.02 Construction Drawings; Bids.

          (a) Upon receipt of the Approved Space Plan, Tenant shall direct the Architect to immediately
begin preparation of Construction Drawings. Tenant shall submit Construction Drawings to Landlord
for Landlord’s approval or comments. Within five (5) Business Days after its receipt of such
documents, Landlord shall notify Tenant in writing of its approval or disapproval, stating in
reasonable detail the reasons for any disapproval.

          (b) If Landlord disapproves the Construction Drawings, Tenant shall then resubmit revised
Construction Drawings to Landlord and Landlord shall approve or disapprove the revised
Construction Drawings within five (5) Business Days after its receipt thereof, stating in
reasonable detail the reasons for any disapproval.

          (c) The foregoing process shall be repeated as many times as are necessary in order to obtain
Construction Drawings which are approved by Landlord and Tenant. When approved by Landlord and
Tenant the Construction Drawings shall be deemed to be the Approved Construction Drawings.
Landlord and Tenant agree to make every effort to expedite the approval of the Space Plan and
Construction Drawings.

          (d) The costs of preparation of the Construction Drawings shall be paid from the Tenant
Improvement Allowance.

     2.03 Change Orders.

          (a) All changes requested by Tenant shall require Landlord’s prior written consent, not to
be unreasonably delayed or withheld. Any Contractor-initiated Change Order must be reviewed and
approved by Landlord and Tenant, which review and approval will not be unreasonably delayed or
withheld. Landlord shall have three (3) Business Days after Landlord’s receipt of any Change
Order to approve or disapprove such Change Order.

          (b) Should any Change Order modify the Approved Construction Drawings, Tenant shall pay the
additional costs thereby incurred as a direct result of such Change Order. All revised or
additional Construction Drawings are subject to Landlord’s prior review and written approval which
shall not be unreasonably delayed or withheld. If and when approved by Landlord, such revised or
additional Construction Drawings shall be deemed to be a part of the Approved Construction
Drawings.

D-2

 

     2.04 Delays. In the event the completion of the Landlord’s Work is delayed due to the
unreasonable failure or refusal of Landlord or Tenant to approve the Space Plan or Construction
Drawings, then the party responsible for such delay (provided such delay results in ten (10) days
or more of delay) shall pay to the other party a penalty equal to one day’s Basic Rent for each
day of delay.

     2.05 Materials and Workmanship. All work and materials required under the Approved
Construction Drawings, including all materials, finishes and workmanship shall be equal to, or of
a quality superior to, building standard, as established for the Building by Landlord’s
architect.

     2.06 Field Verification. Architect shall verify at the job site all dimensions, locations and
structural members and any physical conditions affecting the Construction Drawings.

ARTICLE 3

LANDLORD’S OBLIGATIONS

     3.01 Construction Contract. After completion of the Construction Drawings, as approved by
Landlord and Tenant, Landlord shall obtain bids from at least two (2) pre-approved contractors for
Landlord’s Work. Tenant, with Landlord’s approval, may also select an alternate contractor for
pricing of some or all of such construction activities, provided no Building Systems are involved.
Following receipt of bids based upon the Space Plan and Construction Drawings, and after providing
Tenant an opportunity to review the bids and revise its Space Plan (at Tenant’s cost) to reduce
the cost of Construction, Landlord and Tenant shall select the contract bid to be accepted,
whereupon Landlord shall enter into a fixed cost construction contract for Landlord’s Work. The
contract shall provide that construction will be expedited and diligently pursued to completion
in accordance with the Construction Drawings and construction schedule agreed upon by Landlord and
Tenant. Landlord shall pay all amounts due and payable under the construction contract, provided
that Landlord’s obligation under this Work Letter shall in no event exceed the Tenant Improvement
Allowance. Tenant shall pay all costs in excess of $15.00 per rentable square foot. In the
event Tenant does not utilize all of the Tenant Improvement Allowance, any remaining funds shall
be credited by Landlord against Basic Rent due under the Lease.

     3.02 Payment for Tenant’s Work. In the event Tenant employs contractors to do Tenant’s Work,
the Tenant agrees to be responsible for payment of same.

     3.03 Delivery of Premises. Landlord shall make a good faith effort to deliver the Premises to
Tenant on or about April 1, 2007. Provided, however, Landlord shall not be responsible for any
delay in delivering the Premises which is the result of (a) Tenant’s failure to respond to
Landlord within the time periods set forth herein; or (b) Tenant making more than three (3)
changes to the Space Plan or more than three (3) changes to the Construction Drawings; or (c) a
Tenant initiated Change Order. Landlord shall provide Tenant with ten (10) Business Days prior
written notice of the anticipated date of Substantial Completion, subject to Punch List items.

     3.04 Punch List. Landlord and Tenant, accompanied by the Contractor and Architect, shall meet
promptly after Tenant takes possession of the Premises for purposes of preparing a Punch List of
items to be repaired, replaced or completed by Contractor or Landlord.

ARTICLE 4

TENANT’S INSTALLATIONS

     In the event Tenant shall desire to make any installations in the Premises (“Tenant’s
Installations”) which are not to be made by Landlord for Tenant, the following shall apply:

     4.01 On condition that such Tenant’s Installations will not require any structural change,
and further provided that all Landlord’s Work and additional work required to be made by Landlord
therein shall have reached a point with respect to which, in Landlord’s reasonable judgment,
exercised in good faith, the making of Tenant’s Installations will not delay or hamper Landlord in
the completion of Landlord’s Work, Tenant may enter the

D-3

 

Premises for the purpose of making Tenant’s Installations, subject, however, to the applicable
provisions of the Lease.

     4.02 Prior to the Commencement Date, any entry by Tenant in or on the Premises shall be at
Tenant’s sole risk and shall be subject to all terms, covenants and the provisions of the Lease.
Tenant’s Installations shall be completed free of all liens and encumbrances.

     4.03 In the event Tenant or any agent, visitor, guest, employee, subcontractor or contractor
of Tenant (“Persons Under Tenant’s Control”) shall enter upon the Premises or any other part of
the Building, Tenant agrees to indemnify and save Landlord free and harmless from and against any
and all claims whatsoever arising out of said entry or any work performed by such Persons Under
Tenant’s Control. Persons Under Tenant’s Control shall coordinate their activities so as to avoid
the intrusion into or disruption of ongoing construction or operation of the Building and the
business operation of other tenants.

     4.04 Only Landlord’s contractors shall be permitted to do any work on the Building Systems.

     4.05 Tenant shall be responsible for supervising Tenant’s Work.

ARTICLE 5

SUBSTANTIAL COMPLETION

     Substantially Completed and Substantial Completion shall have occurred upon the following (1)
Work shall have been completed in substantial compliance with the Construction Drawings, except for
Punch List items and Tenant’s Work, and otherwise sufficient so that Architect can execute the most
recently published version of AIA form G704, titled “Certificate of Substantial Completion,” and
(2) Landlord shall have obtained a Certificate of Occupancy or other evidence reasonably
satisfactory to Tenant that upon completion of Tenant’s Work, a Certificate of Occupancy will be
issued, permitting the lawful use of the Premises.

	 	 	 	 	 	 	 	 	 

	LANDLORD:	 	 	 	RIVERSIDE AVENUE PARTNERS, LTD.
	 
	 	 	 	 	 	 	 	 
	 	 	 	 	By:	 	RAP Property Management, LLC, as its 

General Partner
	 
	 	 	 	 	 	 	 	 
	 

	 	 	 	 	 	By:	 	 
	 

	 	 	 	 	 	 	 	 
	 

	 	 	 	 	 	Name:	 	 
	 

	 	 	 	 	 	 	 	 
	 

	 	 	 	 	 	Title:	 	 
	 

	 	 	 	 	 	 	 	 
	 
	 	 	 	 	 	 	 	 
	TENANT:

	 	 	 	EVERBANK	 	 	 	 
	 
	 	 	 	 	 	 	 	 
	 	 	 	 	By:	 	/s/ W. Blake Wilson
	 	 	 	 	 	 	 
	 	 	 	 	Name:	 	W. Blake Wilson
	 	 	 	 	Title:	 	President
	 	 	 	 		 	

D-4

 

EXHIBIT E

CONFIRMATION OF COMMENCEMENT DATE

                    , 2006

                                        

                                        

                                        

                                        

			
	          Re:	 	Lease Agreement (the “Lease”) dated                     , 200_, between Riverside Avenue
Partners, Ltd. (“Landlord”), and                                                              (“Tenant”).
Capitalized terms used herein but not defined shall be given the meanings assigned
to them in the Lease.

Ladies and Gentlemen:

          Landlord and Tenant agree as follows:

     1. Condition of Premises. Tenant has accepted possession of the Premises pursuant to
the Lease. Any improvements required by the terms of the Lease to be made by Landlord have been
completed to the full and complete satisfaction of Tenant in all respects except for the punchlist
items described on Exhibit A hereto (the “Punchlist Items”), and except for such
Punchlist Items, Landlord has fulfilled all of its duties under the Lease with respect to such
initial tenant improvements. Furthermore, Tenant acknowledges that the Premises are suitable for
the Permitted Use.

     2. Commencement Date. The Commencement Date of the Lease is                     , 200___.

     3. Expiration Date. The Term is scheduled to expire on the last day of the ___ the full
calendar month of the
Term, which date is                     , 200___.

     4. Contact Person. Tenant’s contact person in the Premises is:

           
                     
                     
              
           
           
               

       
                  
     
                    
          
                   
                   
      

      
  
       
                  
                   
  
                   
  
      
               
     

Attention:               
                  
                 
          
      
                  
    

Telephone: _______-___________-_____

Telecopy: _______-___________-_____

     5. Ratification. Tenant hereby ratifies and confirms its obligations under the Lease,
and represents and warrants to Landlord that it has no defenses thereto. Additionally, Tenant
further confirms and ratifies that, as of the date hereof: (a) the Lease is and remains in good
standing and in full force and effect; and (b) Tenant has no claims, counterclaims, set-offs or
defenses against Landlord arising out of the Lease or in any way relating thereto or arising out
of any other transaction between Landlord and Tenant.

     6. Binding Effect; Governing Law. Except as modified hereby, the Lease shall remain in
full effect and this letter shall be binding upon Landlord and Tenant and their respective
successors and assigns. If any inconsistency

E-1

 

exists or arises between the terms of this letter and the terms of the Lease, the terms of this
letter shall prevail. This letter shall be governed by the laws of the state in which the Premises
are located.

     Please indicate your agreement to the above matters by signing this letter in the space
indicated below and returning an executed original to us.

	 	 	 	 	 

	 	 	Sincerely,
	 
	 	 	 	 
	 	 	 
	 
	 	 	 	 
	 

	 	By:	 	 
	 

	 	 	 	 
	 

	 	Name:	 	 
	 

	 	 	 	 
	 

	 	Title:	 	 
	 

	 	 	 	 

	 	 	 	 	 	 	 

	Agreed and accepted:	 	 	 	 
	 
	 	 	 	 	 	 
	 	 	 	 	 
	 
	 	 	 	 	 	 
	By:
	 	 	 	 	 	 
	 
	 	 	 	 	 
	Name:
	 	 	 	 	 	 
	 
	 	 	 	 	 
	Title:
	 	 	 	 	 	 
	 
	 	 	 	 	 

E-2

 

EXHIBIT A

PUNCHLIST ITEMS

Please insert any punchlist items that remain to be performed by Landlord. If no items are listed
below by Tenant, none shall be deemed to exist.

E-3

 

EXHIBIT F

FORM OF TENANT ESTOPPEL CERTIFICATE

     The undersigned is the Tenant under the Lease (defined below) between                     , a
___, as Landlord, and the undersigned as Tenant, for the
Premises on the
                     floor(s) of
the office building located at                      Riverside Avenue, Jacksonville, Florida, and commonly known as
                    , and hereby certifies as follows:

     7. The Lease consists of the original Lease Agreement dated as of                     , 200           between Tenant and
Landlord[’s predecessor-in-interest] and the following amendments or modifications thereto (if
none, please state “none”):

      

      

      

     The
documents listed above are herein collectively referred to as the
“Lease” and
represent the entire agreement between the parties with respect to the Premises. All capitalized
terms used herein but not defined shall be given the meaning assigned to them in the Lease.

     8. The Lease is in full force and effect and has not been modified, supplemented or amended
in any way except as provided in Section 1 above.

     9. The Term commenced on ____, 200___ and the Term expires, excluding any renewal
options, on                     , 200____, and Tenant has no option to purchase all or any part of the Premises
or the Building or, except as expressly set forth in the Lease, any option to terminate or cancel
the Lease.

     10. Tenant currently occupies the Premises described in the Lease and Tenant has not
transferred, assigned, or
sublet any portion of the Premises nor entered into any license or concession agreements with
respect thereto except
as follows (if none, please state “none”):

      

      

      

     11. All monthly installments of Basic Rent, all Additional Rent and all monthly installments
of estimated
Additional Rent have been paid when due through                     . The current monthly installment of Basic
Rent
is
$          .

     12. All conditions of the Lease to be performed by Landlord necessary to the enforceability
of the Lease have been satisfied and Landlord is not in default thereunder. In addition, Tenant
has not delivered any notice to Landlord regarding a default by Landlord thereunder.

     13. As of the date hereof, there are no existing defenses or offsets, or, to the
undersigned’s knowledge, claims or any basis for a claim, that the undersigned has against
Landlord and no event has occurred and no condition exists, which, with the giving of notice or
the passage of time, or both, will constitute a default under the Lease.

     14. No
rental has been paid more than 30 days in advance and no security deposit has been
delivered to Landlord except as provided in the Lease.

     15. If Tenant is a corporation, partnership or other business entity, each individual
executing this Estoppel Certificate on behalf of Tenant hereby represents and warrants that Tenant
is a duly formed and existing entity qualified to do business in the state in which the Premises
are located and that Tenant has full right and authority to execute and deliver this Estoppel
Certificate and that each person signing on behalf of Tenant is authorized to do so.

F-1

 

     16. There are no actions pending against Tenant under any bankruptcy or similar laws of the
United States or any state.

     17. Other than in compliance with all applicable laws and incidental to the ordinary course
of the use of the Premises, the undersigned has not used or stored any hazardous substances in the
Premises.

     18. All tenant improvement work to be performed by Landlord under the Lease has been
completed in accordance with the Lease and has been accepted by the undersigned and all
reimbursements and allowances due to the undersigned under the Lease in connection with any tenant
improvement work have been paid in full.

     Tenant acknowledges that this Estoppel Certificate may be delivered to Landlord, Landlord’s
Mortgagee or to a prospective mortgagee or prospective purchaser, and their respective successors
and assigns, and acknowledges that Landlord, Landlord’s Mortgagee and/or such prospective mortgagee
or prospective purchaser will be relying upon the statements contained herein in disbursing loan
advances or making a new loan or acquiring the property of which the Premises are a part and that
receipt by it of this certificate is a condition of disbursing loan advances or making such loan or
acquiring such property.

	 	 	 	 	 	 

	          Executed as of                     , 200     .	 	 	 
	 
	 	 	 	 	 
	 

	 	 
	, a

					

	TENANT:

	 	 
	 	 
	 
	 	 	 	 
	 	 	 
 

	 
	 	 	 	 
	 

	 	By:	 	 
	 

	 	Name:
	 	 
 
	 

	 	Title:
	 	 
 
	 

	 	 	 	 
 

F-2

 

EXHIBIT G

PARKING

          Landlord hereby leases to Tenant and Tenant hereby accepts from Landlord the following
parking spaces: 10 reserved or unreserved parking spaces in the Parking Garage
contiguous to the Building (collectively, the “Parking Garage”). Pricing for each such parking
space shall be as follows: $130.00 per reserved parking space, $80.00 per unreserved parking
space. Pricing is subject to increase each Lease year.

          Tenant shall at all times comply with all Laws respecting the use of the Parking Garage.
Landlord reserves the right to adopt, modify, and enforce reasonable rules and regulations
governing the operation and use of the Parking Garage from time to time. Tenant shall have access
to the Parking Garage at all times except as may be required for maintenance and repair. Landlord
may refuse to permit any person who violates such rules and regulations to park in the Parking
Garage, and any violation of the rules and regulations shall subject the car to removal from the
Parking Facilities.

          Tenant may validate visitor parking by such method or methods as Landlord may approve, at the
validation rate from time to time generally applicable to visitor parking. Except for reserved
parking, the parking spaces provided hereunder shall be provided on an unreserved, “first-come,
first served” basis. Tenant acknowledges that Landlord has arranged or may arrange for the Parking
Garage to be operated by an independent contractor, not affiliated with Landlord.

          There will be a replacement charge payable by Tenant equal to the amount posted from time to
time by Landlord for loss of any magnetic parking card or parking sticker issued by Landlord.

          If, for any reason, Landlord is unable to provide all or any portion of the parking spaces to
which Tenant is entitled hereunder, then Tenant’s obligation to pay for such parking spaces shall
be abated for so long as Tenant does not have the use thereof; this abatement shall be in
settlement of all claims that Tenant might otherwise have against Landlord because of Landlord’s
failure or inability to provide Tenant with such parking spaces. Landlord shall not be responsible
for enforcing Tenant’s parking rights against any third parties.

          Landlord assumes no responsibility whatsoever for loss or damage to any vehicle or its
contents, however
caused. Vehicles should be locked and valuables should not be left
in the vehicle.

          No refunds, credits or allowances will be granted to Tenant for absence, vacation or other
non-use of the Parking Facilities by Tenant or its employees.

          Tenant shall defend, indemnify and hold landlord harmless from and against any and all
actions, claims, liabilities, losses, expenses or damages incurred by Landlord attributable to the
carelessness, negligence or fault of Tenant or any of its agent, employees, or invitees from any
cause, including property damage, injury or death to any person or persons.

G-1

 

EXHIBIT H

RENEWAL OPTION

     Provided no Event of Default exists and Tenant is occupying the entire Premises at the time
of such election, Tenant may renew this Lease for up to three (3) additional periods of five (5)
years, by delivering written notice of the exercise thereof to Landlord on or before 180 days
before the expiration of the Term, as the same may be extended hereby. The Basic Rent payable for
each month during such extended Term shall be the prevailing rental
rate (the “Prevailing
Rental Rate”), at the commencement of such extended Term, for renewals of space in buildings
of equivalent quality, size, utility and location, with the length of the extended Term and the
credit standing of Tenant to be taken into account. Within 30 days after receipt of Tenant’s
notice to renew, Landlord shall deliver to Tenant written notice of the Prevailing Rental Rate and
shall advise Tenant of the required adjustment to Basic Rent, if any, and the other terms and
conditions offered. Tenant shall, within ten days after receipt of Landlord’s notice, notify
Landlord in writing whether Tenant accepts or rejects Landlord’s determination of the Prevailing
Rental Rate. If Tenant timely notifies Landlord that Tenant accepts Landlord’s determination of
the Prevailing Rental Rate, then, on or before the commencement date of the extended Term,
Landlord and Tenant shall execute an amendment to this Lease extending the Term on the same terms
provided in this Lease, except as follows:

               (a) Basic Rent shall be adjusted to the Prevailing Rental Rate;

               (b) Landlord shall lease to Tenant the Premises in their then-current condition, and Landlord
shall not provide to Tenant any allowances (e.g., moving allowance, construction allowance, and
the like) or other tenant inducements; and

               (c) Tenant shall pay for the parking spaces which it is entitled to use at the rates from
time to time charged to patrons of the Parking Facilities and/or any other Parking Facilities
associated with the Building during the extended Term (plus all applicable taxes).

In the event Tenant rejects Landlord’s quoted Prevailing Rental Rate, Landlord and Tenant shall
each select an MAI appraiser with substantial experience in the downtown Jacksonville, Florida,
office market for the purpose of making a determination of the prevailing market rental rate in
downtown Jacksonville, Florida for comparable office space which has been built out for occupancy;
if Landlord or Tenant fails to notify the other of the identity of its selected appraiser within
thirty (30) days of the other’s written demand therefor (which demand shall identify the notifying
party’s appraiser and make reference to this provision’s consequences for failure to identify the
appraiser), the party who failed to identify its appraiser shall be deemed to have consented to
the Prevailing Rental Rate determined in good faith by the appraiser selected by the other party.
Assuming that both appraisers are timely selected, the two selected appraisers shall each then
make an independent determination of the Prevailing Rental Rate and they shall together select a
third MAI appraiser, similarly experienced, who shall select which of the two (2) determinations
it believes to be most accurate. The chosen determination shall be final and not subject to
appeal. Each party to the Lease shall pay the fees and costs of its own appraiser and one-half of
the fees and costs of the jointly-selected appraiser.

     Tenant’s rights under this Exhibit shall terminate if (1) this Lease or Tenant’s right to
possession of the Premises is terminated, (2) Tenant fails to timely exercise its option under
this Exhibit, time being of the essence with respect to Tenant’s exercise thereof, or (3) Landlord
determines, in its sole but reasonable discretion, that Tenant’s financial condition or
creditworthiness has materially deteriorated since the date of this Lease.

H-1

 

EXHIBIT I

INTENTIONALLY DELETED

I-1

 

EXHIBIT J

SIGNAGE

     Landlord shall provide Tenant the exclusive right to Building signage on the top floor facia
of the Building and on the roof. The design, size and exact location of the signage shall be
subject to review and approval by Landlord, which approval shall not be unreasonably withheld.

J-1

 

EXHIBIT K 

OPERATING COSTS

     “Operating Costs” shall include the reasonable costs of ownership, operation,
maintenance and management of the Project, in accordance with generally accepted accounting
principles consistently applied. Any Operating Costs incurred after the expiration of the Term of
this Lease shall be excluded from Operating Costs (unless incurred during the period of any
Tenant holdover). Any local real estate tax incentives or abatements received by Landlord from
local authorities shall be passed through to Tenant to the extent of Tenant’s Share, net of the
cost of obtaining such incentives or abatements; provided that Landlord shall have no obligations
to seek or obtain any such incentives or abatements.

     A. Items Included in Operating Costs:

     (1) all real estate taxes, assessments, governmental charges, rental taxes (to the extent
enacted as a substitute for real estate taxes, as opposed to as a substitute for income taxes)
attributable to the Project; provided, however, that:

     (a) no real estate taxes shall be included in Operating Costs until such time as the
appropriate taxing authority has rendered to Landlord a tax bill based on the assessed
valuation of the Project;

     (b) for the purpose of determining Operating Costs, real estate taxes shall be deemed
paid as of the first month payable so that the amount of real estate taxes included in
Operating Costs shall not exceed the maximum discounted payment amount (provided, however,
that Landlord may actually pay the real estate taxes at any time before the same are
considered delinquent);

     (c) for the purpose of determining Operating Costs, assessments (but not real estate
taxes) shall be deemed paid over the longest pay-out period authorized by the assessing
authority so that only the installments which must be paid during the particular year shall
be included as an Operating Costs; and

     (d) with regard to governmental charges, such term shall apply only to charges related
to the Project and shall not include franchise, estate, inheritance, capital stock, income,
excess profits or similar taxes imposed upon Landlord;

     (2) salaries, wages, and all other expenses incurred for the employment of a Project staff,
including, without limitation, janitorial, security, Building repair and maintenance, but
excluding those staff members above the grade of building manager and/or equally held positions;

     (3) the cost of materials and supplies used in the operation, repair and maintenance of the
Project and landscaped areas;

     (4) the cost of replacements for tools and equipment used in the operation, repair and
maintenance of the Project, it being agreed that such equipment shall not include air conditioning
equipment, boilers, elevators or any items of a capital nature;

     (5) amounts charged to Landlord by independent contractors for services (including full or
part-time labor), materials and supplies furnished in connection with the operation, repair and
maintenance of any part of the Project, the sidewalks and landscaping around the Building and the
heating, air conditioning, ventilating, plumbing, electrical and elevator systems of the Project;

     (6) amounts paid by Landlord, or charged to Landlord by independent contractors, for
security, window cleaning, parking lot cleaning and janitorial, rubbish removal and porter services;

K-1

 

     (7) water charges, sewer rents and charges (including applicable taxes) for electricity and
other utilities required in the operation of those areas of the Parking Garage and ground level
Common Areas of the Building (For the sake of clarification, Tenant shall be responsible for
paying the entire cost of its use of Utilities);

     (8) the cost of repainting for the lobby, the public stairwells of the Project, the Project
elevator shafts and all other public portions thereof;

     (9) Christmas decorations for the lobby and other public portions of the Project below the
second floor;

     (10) the cost of telephone service, postage, office supplies, maintenance and repair of
office equipment and similar charges related to operation of the building manager’s office;

     (11) the cost of licenses, permits and similar fees and charges related to the operation,
repair and maintenance of the Project (including the tenanted areas thereof);

     (12) premiums for insurance obtained by Landlord pursuant to the requirements of the Lease;

     (13) fees for the management of the Project, not exceeding those fees customarily charged
for comparable buildings and excluding any leasing commissions or compensations;

     (14) capital improvements made to the Project which although capital in nature either (a) can
reasonably be expected to reduce the normal operating costs of the Project, or (b) are made in
order to comply with any statutes, rules, regulations or directives hereafter promulgated by any
governmental authority or board of fire underwriters (and do not result from defects in the
original design or construction of the Building), with the cost of each capital improvement to be
amortized in equal increments over the useful life- of such improvement (regardless of
whether or not the useful life extends beyond the termination of this Lease), and with capital
improvements referred to in item (a) of this subsection to be subject to withdrawal from Operating
Costs to the extent it is subsequently determined in accordance with Section 4.02(b) that normal
operating costs of the Building were not reduced by the capital improvements;

     (15) items expressly to be included as an Operating Costs pursuant to this Lease; and

     (16) except as expressly limited by any of the items referred to in subsection B, such other
reasonable costs and expenses actually incurred by Landlord in the maintenance, repair, and
operation of the Project, but only to the extent that such other costs and expenses are
customarily incurred and included as an Operating Costs by other landlords of comparable
buildings.

     Operating Costs shall be “net” only, and for that purpose shall be reduced by the amounts of
any reimbursement, refund or credit received or receivable by Landlord (net of the reasonable
costs and expenses of obtaining the same, if any) with respect to any item of cost that is
included in Operating Costs; provided that Landlord shall have no obligation to seek or obtain
any such reimbursement, refund or credit. In the event any such reimbursement, refund or credit
is received or receivable by Landlord in a later year, it shall be applied against the Operating
Costs for such later year; provided, however, that if the term of this Lease has then expired,
Tenant’s Share of such item shall promptly be refunded by Landlord to Tenant.

     B. Items Excluded from Operating Costs;

     (1) the cost of any work or service performed for Tenant at Tenant’s direct cost;

     (2) the cost of correcting defects in the design or construction of the Building, but
excluding ordinary wear and tear to the Building;

     (3) salaries of officers and executives of Landlord;

     (4) the cost of any items for which Landlord is reimbursed by insurance or otherwise;

K-2

 

     (5) the cost of any improvements, additions or alterations to the Building after the
original construction, except to the extent provided in subsection 14 of A above;

     (6) the cost of any repairs, alterations, additions, changes, replacements and other items
which under generally accepted accounting principles are properly classified as capital
expenditures, except to the extent provided in subsection 14 of A above;

     (7) interest on debt or amortization payments on any mortgage and rental under any ground
lease or other underlying lease;

     (8) any real estate brokerage commissions;

     (9) any advertising expenses;

     (10) any costs included in Operating Costs representing an amount paid to an entity or
person related to Landlord to the extent such amount is in excess of the amount which would
have been paid in the absence of such relationship;

     (11) any costs of painting or decorating of any tenanted part of the Building;

     (12) lease payments for rented equipment, the cost of which equipment (a) would constitute
a capital expenditure if the equipment were purchased, and (b) would not qualify under
subsection 14 of Category A above;

     (13) any expenses for repairs or maintenance which are covered by warranties and service
contracts;

     (14) any expenses specifically excluded from Operating Costs by the other provisions of
this Lease; or

     (15) accounting and/or legal fees which relate to a Tenant Dispute.

     (16) Tenant will assume direct responsibility to the providers of the following services:
(a) electricity; (b) telephone; (c) pest control; (d) Sanitary Services; and (e) security for
its Premises. Therefore, for purposes of calculating Operating Costs such items will not be
included.

K-3exv10w11

Exhibit
10.11

AMENDED AND RESTATED

REGISTRATION RIGHTS AGREEMENT

     AMENDED AND RESTATED REGISTRATION RIGHTS AGREEMENT, dated as of November 22, 2002 by and among
ALLIANCE CAPITAL PARTNERS, L.P., a Delaware limited partnership (the “Partnership”), and
the persons listed on Schedule 1 to this Agreement (the “Investors”).

RECITALS:

     WHEREAS, simultaneously with the execution and delivery of this Agreement, the Partnership
and certain of the Investors are entering into a Securities Purchase Agreement dated as of the
date hereof (the “2002 Purchase Agreement”) pursuant to which the Investors will purchase
common units of limited partnership interest in the Partnership (“Units”); and

     WHEREAS, in connection with the previous purchase of Units pursuant to the Securities
Purchase Agreement dated as of October 27, 2000 among the Partnership and certain of the Investors
(the “2000 Purchase Agreement”), the parties thereto entered into that Registration Rights
Agreement, dated as of October 27, 2000 (the “2000 Registration Agreement”); and

     WHEREAS, the parties hereto desire to amend and restate the 2000 Registration Agreement in
connection with the 2002 Purchase Agreement to reflect the relative rights and obligations of the
Investors; and

     WHEREAS, the execution and delivery of this Agreement is a condition to the closing of the
2002 Purchase Agreement.

     NOW, THEREFORE, in consideration of the premises and mutual covenants and agreements of the
parties as set forth herein and other good and valuable consideration, receipt of which is hereby
acknowledged, the parties hereto agree as follows:

     Section 1. Definitions. As used in this Agreement, the following terms shall have the
following respective meanings:

     “Board of Directors” shall mean the board of directors of the General Partner or any
other body charged with comparable responsibilities on behalf of the Partnership.

     “Commission” shall mean the Securities and Exchange Commission or any other federal
agency at the time administering the Securities Act.

     “Exchange Act” shall mean the Securities Exchange Act of 1934, as amended, and the
rules and regulations thereunder, and shall include any successor federal statute.

 

 

     “General Partner” shall mean Alliance Capital Partners, Inc. or such other general
partner of the Partnership as may be designated from time to time.

     “Holder” shall mean any holder of outstanding Registrable Securities, including,
without limitation, any transferee in accordance with Section 10.

     “Initial Public Offering” shall mean the Partnership’s first firm commitment
underwritten public offering of Units, pursuant to a registration statement filed with and
declared effective by the Commission.

     “Initiating Holders” shall mean the holders of a majority-in-interest of the
aggregate Units purchased by the Investors pursuant to the 2000 Purchase Agreement and the 2002
Purchase Agreement.

     “Register,” “registered” and “registration” shall refer to a
registration effected by preparing and filing a registration statement in compliance with the
Securities Act, and the declaration or ordering of the effectiveness of such registration
statement.

     “Registered Securities” shall mean Registrable Securities which have been registered
under the Securities Act pursuant to a registration statement filed with and declared effective by
the Commission.

     “Registrable Securities” shall mean Units now owned or hereafter acquired by the
Investors, including, without limitation, Units issued by way of stock split or stock dividend or
any other securities issued in exchange for Units in connection with a merger, recapitalization or
other reorganization. For purposes of this Agreement, a Person shall be deemed to be a holder of
Registrable Securities, and the Registrable Securities shall be deemed to be in existence,
whenever such Person has the right to acquire directly or indirectly such Registrable Securities
(upon conversion or exercise, in connection with a transfer of securities or otherwise, but
disregarding any restrictions or limitations upon the exercise of such right), whether or not such
acquisition has actually been effected, and such Person shall be entitled to exercise the rights
of a holder of Registrable Securities hereunder. As to any particular Registrable Securities, such
securities will cease to be Registrable Securities when (i) they have been effectively registered
under the Securities Act and disposed of in accordance with the Registration Statement covering
them, (ii) they have ceased to be Restricted Securities pursuant to Rule 144(k) (or any successor
provision), (iii) they are distributed to the public pursuant to Rule 144 (or any similar
provision then in force) under the Securities Act, or (iv) they are otherwise freely transferable
without restriction under the Securities Act, and the Holders thereof have received an opinion of
their legal counsel to such effect.

     “Registration Expenses” shall mean all expenses incurred by the Partnership in
compliance with Sections 2, 3 and 5 hereof, including, without limitation, all registration, filing
and National Association of Securities Dealers fees, all fees and expenses of complying with
federal securities or state blue sky or securities laws, all word processing, duplicating and
printing expenses, messenger, tele-communications, mailing and delivery

2

 

expenses, the fees and disbursements of counsel for the Partnership and of its independent public
accountants, including the expenses of any special audits or “comfort” letters required by or
incident to such performance and compliance, the reasonable fees and disbursements incurred by the
holders of Registrable Securities to be registered (including the reasonable fees and disbursements
of one law firm retained by such Holders in accordance with Sections 2 or 3 hereof), and any
expenses incurred in connection with any road show and any other fees and disbursements of
underwriters customarily paid by issuers or sellers of securities, but excluding Selling Expenses,
if any.

     “Rule 144” shall mean Rule 144 promulgated under the Securities Act, or any
successor rule then in force.

     “Securities Act” shall mean the Securities Act of 1933, as amended, and the rules and
regulations thereunder, and shall include any successor federal statute.

     “Selling Expenses” shall mean all underwriting discounts and selling commissions
applicable to the sale of Registrable Securities.

     Section 2. Requested Registration.

          (a) Request for Registration. Subject to Section 11 (a), if, at any time after the
earlier of: (i) October 27, 2005 or (ii) the date of closing of the Initial Public Offering, the
Partnership shall receive from Initiating Holders a written request that the Partnership effect
any registration with respect to all or part of the Registrable Securities, the Partnership will:

          (1) promptly give written notice of the proposed registration to all other Holders;
and

          (2) as soon as practicable, use its commercially reasonable efforts to effect such
registration (including, without limitation, the execution of an undertaking to file
post-effective amendments, appropriate qualification under applicable blue sky or other
state securities laws and appropriate compliance with the Securities Act) as may be so
requested and as would permit or facilitate the sale and distribution of all or such
portion of such Registrable Securities as are specified in such
request, together with all
or such portion of the Registrable Securities of any Holder or Holders joining in such
request as are specified in a written request given within twenty-five (25) days after
receipt of such written notice from the Partnership pursuant to Sections 2 or 3 hereof;
provided, however, that the Partnership shall not be obligated to effect, or to take any
action to effect, any such registration pursuant to this Section 2:

          (A) After the Partnership has effected three such Registrations pursuant to
this Section 2 upon the request of the Initiating Holders, and all such
registrations have been declared or ordered effective and

3

 

maintained effective for at least 270 days (or less if all the Registrable
Securities included therein are sooner sold); or

          (B) If common units of the Partnership have not been sold to the public
pursuant to a registration statement filed with and declared effective by the
Commission under the Securities Act, and within thirty (30) days after receipt of a
request pursuant to this Section 2, the Partnership informs the Initiating Holders
that in lieu of registering the Registrable Securities of the Holders, the
Partnership intends to register and sell securities for its own account (within
four (4) months of receipt of such request pursuant to this Section 2) and the
Partnership gives the Holders the notice required by Section 3(a)(1) of this
Agreement.

     Subject to the foregoing clauses (A) and (B), the Partnership shall file a registration
statement covering the Registrable Securities so requested to be registered as soon as practicable
after receipt of the request or requests of the Initiating Holders, but in no event later than 90
days thereafter, and shall use all commercially reasonable efforts to cause the same to be
declared effective by the Commission as promptly as practicable after such filing. For purposes of
a registration under this Section 2, a majority-in-interest of the Initiating Holders shall have
the right to select the counsel for all of the selling Holders.

     Notwithstanding the foregoing, (i) the Partnership may, prior to the filing of any
registration statement requested pursuant to this Section 2, delay the filing of such registration
statement for a reasonable period of time (not to exceed 180 days after the request for filing a
registration statement) if within five days of a resolution of the Board of Directors determining
to delay such filing, the Partnership provides the Initiating Holders with a certificate signed by
the Chairman of the Board of Directors stating that, in the good faith judgment of the Board of
Directors, such registration is not then in the best interests of the Partnership; provided that
the Partnership may only defer one registration statement pursuant to this clause (i), and (ii) the
Partnership may, prior to the filing of any registration statement requested pursuant to this
Section 2, delay the filing of such registration statement for a reasonable period of time (not to
exceed 120 days after the request for filing a registration statement) if within five days of a
resolution of the Board of Directors determining to delay such filing, the Partnership provides the
Initiating Holders with a certificate signed by the Chairman of the Board of Directors stating
that, in the good faith judgment of the Board of Directors, the filing of the registration
statement would require disclosure of information not otherwise then required to be disclosed and
that such disclosure would adversely affect any material business opportunity, transaction or
negotiation then contemplated by the Partnership; provided that the Partnership may defer the
filing of a registration statement under this clause (ii) only once in any 12-month period. The
Partnership shall give prompt notice to the Initiating Holders of the end of any delay period under
this subsection.

     The registration statement filed pursuant to the request of the Initiating Holders may,
subject to the provisions of Section 2(b) below, include securities (other than Registrable

4

 

Securities) of the Partnership which are held by partners of the Partnership other than the
Investors (the “Other Partners”) or securities of the Partnership for its own account.

          (b) Underwriting. If the Initiating Holders intend to distribute the Registrable
Securities covered by their request by means of an underwriting, they shall so advise the
Partnership as a part of their request made pursuant to Section 2 and the Partnership shall
include such information in the written notice referred to in Section 2(a)(1) above. A
majority-in-interest of the Initiating Holders shall have the right to select the lead investment
banker and manager, and any co-managers (all of which shall be nationally recognized firms), to
administer the offering, subject to the Partnership’s approval which will not be unreasonably
withheld or delayed. The right of any Holder to registration pursuant to this Section 2 shall be
conditioned upon such Holder’s participation in such underwriting and the inclusion of such
Holder’s Registrable Securities in the underwriting (unless otherwise mutually agreed by a
majority-in-interest of the Initiating Holders and such Holder with respect to such participation
and inclusion) to the extent provided herein.

     If Holders or Other Partners shall request inclusion in any registration to be effected
pursuant to this Section 2, the Initiating Holders shall offer to include the securities of such
Holders and Other Partners in the underwriting and may condition such offer on their acceptance of
the further applicable provisions of this Agreement. The Partnership shall (together with all
Holders and Other Partners proposing to distribute their securities through such underwriting)
enter into an underwriting agreement in customary form with the underwriter or underwriters
selected for such underwriting. Notwithstanding any other provision of this Section 2, if the
managing underwriter advises the Initiating Holders in writing that marketing factors require a
limitation on the number of shares to be underwritten, the securities being sold for the account of
the Partnership and the securities of the Partnership (other than Registrable Securities) held by
the Other Partners shall be excluded from such registration to the extent so required by such
limitation, and if a further limitation of the number of shares is required, the Initiating Holders
shall so advise all Holders of Registrable Securities requesting registration pursuant to this
Section 2, and the number of shares of Registrable Securities that may be included in the
registration and underwriting shall be allocated among all such Holders (including the Initiating
Holders) in proportion, as nearly as practicable, to the respective
amounts of Registrable
Securities which they had requested to be included in such registration. No Registrable Securities
or any other securities excluded from the underwriting by reason of the underwriter’s marketing
limitation shall be included in such registration. If any Holder or Other Partner who has requested
inclusion in such registration disapproves of the terms of the underwriting, such person may elect
to withdraw therefrom by written notice to the Partnership, the managing underwriter and the
Initiating Holders. The securities so withdrawn shall also be withdrawn from such registration
unless otherwise agreed in accordance with the last sentence of the first paragraph of this Section
2(b).

5

 

     Section 3. Piggyback Registration.

          (a) If the Partnership proposes or is required to register any of its securities either for
its own account or the account of a security holder or holders, other than a registration on Forms
S-4 or S-8 or any successor forms thereto or any form which does not permit secondary sales, the
Partnership will:

          (1) Promptly give to each Holder written notice thereof; and

          (2) include in such registration, and in any underwriting involved therein, all the
Registrable Securities specified in a written request or requests made by any Holder within
fifteen (15) days after receipt of the written notice from the Partnership described in
clause (1) above, except as set forth in Section 3(b) below. Such written request may
specify all or a part of a Holder’s Registrable Securities.

     For purposes of any registration pursuant to this Section 3, the holders of a
majority-in-interest of the securities to be registered shall choose the counsel for all of the
selling holders.

          (b) Underwriting. If the registration of which the Partnership gives notice is for a
registered public offering involving an underwriting, the Partnership shall so advise the Holders
as a part of the written notice given pursuant to Section 3(a)(1). All Holders proposing to
distribute their securities through such underwriting shall (together with the Partnership and the
Other Partners distributing their securities through such underwriting) enter into an underwriting
agreement mutually agreeable to the underwriter or underwriters selected by the Partnership and
each selling Holder, it being understood that the Partnership shall have no liability to any
selling Holder which cannot reach agreeable terms with the underwriter(s) and the sole remedy
available to any selling Holder which does not agree with the terms of the underwriting agreement
is to not participate in such underwriting. Notwithstanding any other provision of this Section 3,
if the managing underwriter advises the Partnership that marketing factors require a limitation on
the number of shares to be underwritten, the Partnership shall so advise all holders of securities
requesting registration, and the number of securities that are entitled to be included in the
registration and underwriting shall be allocated in the following manner: (i) if securities are
being registered pursuant to demand registration rights, then first to the securities held by the
security holder exercising such demand registration rights and second to the securities of the
Partnership and the Other Partners and all Holders requesting inclusion in the registration
pursuant to this Section 3 (pro rata based upon the number of securities requested to be included
in such registration by the Partnership and each such Holder or Other Partner), and (ii) if
securities of the Partnership are being registered for the Partnership’s own account (and no
demand registration rights have been exercised), then first to the Partnership and second to the
securities of the Other Partners and all Holders requesting inclusion in the registration pursuant
to this Section 3 (pro rata based upon the number of securities requested to be included in such
registration by each such Holder or Other Partner). If any Holder of Registrable Securities or
Other Partner disapproves of the

6

 

terms of any such underwriting, he may elect to withdraw therefrom by written notice to the
Partnership and the managing underwriter. Any Registrable Securities or other securities excluded
or withdrawn from such underwriting shall be withdrawn from such registration. Any registration of
Registrable Securities effected pursuant to this Section 3 shall not constitute a demand
registration under Section 2(a)(2)(A) hereof.

     Section 4. Expenses of Registration. All Registration Expenses incurred in connection
with any registration, qualification or compliance pursuant to this Agreement shall be borne by
the Partnership, and all Selling Expenses with respect to Registrable Securities included in such
registration shall be borne by the Holders of the Registrable Securities so registered; provided,
however, that the Partnership shall not be required to pay any Registration Expenses if, as a
result of the withdrawal of a request for registration by the Initiating Holders (other than as a
result of a material adverse change in the Partnership’s business, operations, financial
condition, operating results or prospects), the registration statement does not become effective,
in which case the Initiating Holders requesting registration shall bear such Registration Expenses
pro rata on the basis of the number of their shares so included in the registration request, and
provided, further, that such registration shall not be counted as a registration pursuant to
Section 2(a)(2)(A). Notwithstanding the proviso in the preceding sentence, the Initiating Holders
may elect to have such withdrawn registration count as a registration pursuant to Section
2(a)(2)(A), in which event the Partnership shall bear all Registration Expenses relating to such
withdrawn registration.

     Section 5. Registration Procedures. In the case of each registration effected by the
Partnership pursuant to this Agreement, the Partnership will keep each Holder advised in writing
as to the initiation of each registration and as to the completion thereof. Whenever Holders have
requested that any Registrable Securities be registered pursuant to this Agreement, the
Partnership will use its commercially reasonable efforts to effect the registration and the sale
of such Registrable Securities in accordance with the intended method of disposition thereof, and
pursuant thereto the Partnership will at its expense and as expeditiously as practicable:

          (a) Prepare and file with the Commission a registration statement with respect to such
Registrable Securities within 90 days of a request for registration under Section 2 and use its
commercially reasonable efforts to cause such registration statement to become effective; provided
that before filing a registration statement or prospectus or any amendment or supplement thereto,
including documents incorporated by reference after the initial filing of any registration
statement, the Partnership shall furnish to the Holders of the Registrable Securities covered by
such registration statement and the underwriters, if any, copies of all such documents proposed to
be filed, which documents will be subject to the review of such Holders and underwriters; provided
that in connection with a registration request pursuant to Section 2, the Partnership shall not
file any registration statement or prospectus, or any amendments or supplements thereto, if the
Holder’s counsel or the managing underwriter shall reasonably object, in writing, on a timely
basis;

7

 

          (b) Prepare and file with the Commission such amendments and post-effective amendments to such
registration statement as may be necessary to keep such registration statement effective for a
period of 270 days or until the Holder or Holders have completed the distribution described in the
registration statement relating thereto, whichever first occurs; provided, however, that the
Partnership, in good faith, may delay the filing of any amendment or supplement to the registration
statement for a reasonable period of time, not to exceed 120 days, in order to permit the
Partnership (A) to effect disclosure or disposition or consummation of any transaction requiring
confidential treatment which is being actively pursued at such time and which would require
disclosure in the registration statement or (B) to negotiate, effect or complete any transaction
which the Partnership reasonably believes might be jeopardized, delayed or made more costly to the
Partnership by disclosure in the registration statement; and provided further, however, that such
270 day period shall be extended by the number of days during the period from and including the
date of the giving of notice pursuant to Section 5(e) hereof to and including the date when each
Holder of Registrable Securities covered by such registration statement shall have received the
copies of the supplemented or amended prospectus contemplated by Section 5(e) hereof;

          (c) Cause the related prospectus to be supplemented by any required prospectus supplement,
and, as so supplemented, to be filed pursuant to Rule 424 under the Securities Act; and comply with
the provisions of the Securities Act with respect to the disposition of all securities covered by
such registration statement during such period in accordance with the intended methods of
disposition by the sellers thereof set forth in such registration statement or supplement to such
prospectus;

          (d) Furnish without charge copies of the registration statement, each amendment and
supplement thereto (in each case including exhibits and documents incorporated by reference), the
prospectus included in the registration statement (including each preliminary prospectus) and any
amendments and supplements to the prospectus and all other documents incident thereto, including
any amendment of or supplement to the prospectus as a Holder from time to time may reasonably
request;

          (e) Notify each seller of Registered Securities covered by such registration statement at any
time when a prospectus relating thereto is required to be delivered under the Securities Act of
the happening of any event as a result of which the prospectus included in such registration
statement, as then in effect, includes an untrue statement of a material fact or omits to state a
material fact required to be stated therein or necessary to make the statements therein, in light
of the circumstances under which they were made, not misleading, and at the request of any such
seller, prepare and furnish to such seller a reasonable number of copies of a supplement to or an
amendment of such prospectus as may be necessary so that, as thereafter delivered to the
purchasers of such shares, such prospectus shall not include an untrue statement of a material
fact or omit to state a material fact required to be stated therein or necessary to make the
statements therein, in light of the circumstances under which they were made, not misleading;

8

 

          (f) Notify each seller of Registrable Securities covered by such registration statement
promptly (i) when a prospectus or any prospectus supplement or post-effective amendment has been
filed, and, with respect to a registration statement or any post-effective amendment, when the same
has become effective under the Securities Act and each applicable state law, (ii) of any request by
the Commission or any other Federal or state governmental authority for amendments or supplements
to a registration statement or related prospectus or for additional information, (iii) of the
issuance by the Commission of any stop order suspending the effectiveness of a registration
statement or the initiation of any proceedings for that purpose, (iv) of the receipt by the
Partnership of any notification with respect to the suspension of the qualification or exemption
from qualification of any of the Registrable Securities for sale in any jurisdiction or the
initiation or threatening of any proceeding for such purpose, (v) if at any time the
representations and warranties contemplated by any underwriting agreement, securities sales
agreement, or other similar agreement relating to the offering shall cease to be true and correct
in all material respects and (vi) of the Partnership’s reasonable determination that a
post-effective amendment to a registration statement would be appropriate;

          (g) Use its commercially reasonable efforts to obtain the withdrawal of any order suspending
the effectiveness of a registration statement, or the lifting of any suspension of the
qualification (or exemption from qualification) of any of the Registrable Securities for sale in
any jurisdiction, at the earliest practicable moment;

          (h) Cause all such Registered Securities to be listed on each securities exchange on which
similar securities issued by the Partnership are then listed or, if not then listed, cause such
Registered Securities to be included on an exchange or national automated quotation system which
the Board of Directors designates in its good faith judgment;

          (i) Provide a transfer agent and registrar for all Registered Securities and a CUSIP number
for all such Registered Securities, in each case not later than the effective date of such
registration;

          (j) Make available for inspection during regular business hours by any seller of Registrable
Securities, any underwriter participating in any disposition pursuant to such registration
statement, and any attorney, accountant or other agent retained by any such seller or underwriter
(collectively, the “Inspectors”), all financial and other records, pertinent corporate
documents and properties of the Partnership (collectively the “Records”) as shall be
reasonably necessary to enable them to exercise their due diligence responsibility, and cause the
Partnership’s officers, directors, employees and independent accountants to supply all information
reasonably requested by such seller, underwriter, attorney or accountant in connection with such
registration statement. Records which the Partnership determines, in good faith, to be
confidential and which it notifies the Inspectors are confidential shall not be disclosed by the
Inspectors unless (A) counsel for the selling Holders advises that the disclosure of such Records
is reasonably necessary to avoid or correct any misstatement or omission in the registration
statement, (B) the release of such

9

 

Records is ordered pursuant to a subpoena or other order from a court of competent jurisdiction,
or (C) the disclosure of such Records is required by any governmental regulatory body with
jurisdiction over any seller of Registrable Securities. Such seller, as soon as reasonably
practicable after learning that disclosure of such Records is sought in a court of competent
jurisdiction, shall notify the Partnership and allow the Partnership, at its expense, to undertake
appropriate action to prevent disclosure of the Records deemed confidential;

          (k) Cooperate with the sellers of Registered Securities and the managing underwriter(s), if
any, to facilitate the timely preparation and delivery of certificates representing the Registered
Securities to be sold, without any restrictive legends, in such denominations and registered in
such names as the managing underwriter(s) may request at least two business days prior to any sale
thereof to the underwriters, if applicable;

          (I) In the case of an underwritten public offering, obtain from its independent public
accountants “comfort” letters, dated the effective date of the registration statement and the date
of the closing of the sale of the Registered Securities, and addressed to the Partnership and the
selling Holders, in form and substance as are customarily issued in connection with underwritten
public offerings and otherwise reasonably satisfactory to the Partnership and, if the registration
is pursuant to Section 2, a majority-in-interest of the Initiating Holders;

          (m) Obtain from its counsel an opinion, addressed to the selling Holders, with respect to the
offering in form and substance reasonably satisfactory to (i) a majority-in-interest of the
Initiating Holders, if the registration is pursuant to Section 2, or (ii) a majority-in-interest of
the selling holders in all other cases;

          (n) Otherwise use its commercially reasonable efforts to comply with all applicable rules and
regulations of the Commission, and make available to its security holders, as soon as practicable,
an earnings statement covering the period of at least twelve months, but not more than eighteen
months, beginning with the first month after the effective date of the registration statement,
which earnings statement shall satisfy the provisions of Section 11(a) of the Securities Act;

          (o) In connection with any underwritten offering pursuant to a registration statement filed
pursuant to Section 2 hereof, the Partnership will enter into customary agreements (including
underwriting agreements) reasonably necessary to effect the offer and sale of Registrable
Securities, provided such agreements contain customary underwriting, indemnification and
contribution provisions, which indemnification and contribution provisions shall be in all material
respects similar to the provisions of Section 7 hereof; provided, however, that no Holder will be
liable for indemnification or contribution in excess of the net proceeds such Holder received in
the offering;

          (p) Use its commercially reasonable efforts to register or qualify such Registrable Securities
under such other securities or blue sky laws of such jurisdictions as

10

 

any seller reasonably requests and do any and all other acts and things which may be reasonably
necessary or advisable to enable such seller to consummate the disposition in such jurisdictions
of the Registrable Securities owned by such seller (provided that the Partnership will not be
required to (i) qualify generally to do business in any jurisdiction where it would not otherwise
be required to qualify but for this subparagraph, (ii) subject itself to taxation in any such
jurisdiction or (iii) consent to general service of process in any such jurisdiction);

          (q) Use its commercially reasonable efforts to cause such Registrable Securities covered by
such registration statement to be registered with or approved by such other governmental agencies
or authorities as may be necessary to enable the sellers thereof to consummate the disposition of
such Registrable Securities;

          (r) Cooperate and assist in any filing required to be made with the NASD and in the
performance of any due diligence investigation by any underwriter, including any “qualified
independent underwriter,” or any selling Holder;

          (s) Cooperate fully with the marketing and sale of securities in accordance with this
Agreement including, without limitation, providing marketing support and causing the appropriate
member(s) of management to participate in “road show” presentations and attend meetings with
underwriters as requested by the Holders or the underwriters; and

          If any such registration statement or comparable statement under “blue sky” laws refers to any
selling Holder by name or otherwise as the selling Holder of any securities of the Partnership,
then such selling Holder shall have the right to require, acting reasonably, (i) the insertion
therein of language, in form and substance satisfactory to such selling Holder, to the effect that
the holding by such selling Holder of such securities is not to be construed as a recommendation by
such selling Holder of the investment quality of the Partnership’s securities covered thereby and
that such holding does not imply that such selling Holder will assist in meeting any future
financial requirements of the Partnership, or (ii) in the event that such reference to such selling
Holder by name or otherwise is not in the judgment of the Partnership, as advised by counsel,
required by the Securities Act or any similar federal statute or any state “blue sky” or United
States securities law then in force, the deletion of the reference to such selling Holder.

          (t) Take all such other actions as the underwriters, if any, and (i) a majority-in-interest
of the Initiating Holders if the registration is pursuant to Section 2 or (ii) a
majority-in-interest of the selling holders in all other cases reasonably request in order to
expedite or facilitate the disposition of such Registrable Securities (including, without
limitation, effecting a stock split or combination of shares).

     Section 6. No Required Sale. Nothing in this Agreement shall be deemed to create an
independent obligation on the part of any Holder to sell any Registrable Securities pursuant to
any effective registration statement.

11

 

     Section 7. Indemnification; Contribution.

          (a) To the extent permitted by law, the Partnership will indemnify each Holder, each of its
officers, directors, members and partners, and each person controlling such Holder, with respect
to which registration, qualification or compliance has been effected pursuant to this Agreement,
and each underwriter, if any, and each person who controls any underwriter, against all claims,
losses, damages, liabilities and judgments (or actions, proceedings or settlements, if such
settlements are effected with the written consent of the Partnership, in respect thereof) arising
out of or based on any untrue statement (or alleged untrue statement) of a material fact contained
in any prospectus, offering circular or other document (including any related registration
statement, notification or the like) incident to any such registration, qualification or
compliance, or any omission (or alleged omission) to state therein a material fact required to be
stated therein or necessary to make the statements therein not misleading, or any violation by the
Partnership of the Securities Act or the Exchange Act or any rule or regulation thereunder
applicable to the Partnership, and will reimburse each such Holder, each of its officers,
directors, members and partners, and each person controlling such Holder, each such underwriter
and each person who controls any such underwriter, for any legal and any other expenses reasonably
incurred in connection with investigating and defending or settling any such claim, loss, damage,
liability, action or proceeding; provided, however, that the Partnership will not be liable in any
such case to the extent that any such claim, loss, damage, liability or expense arises out of or
is based on any untrue statement or omission made in such registration statement, prospectus,
offering circular or other document in reliance upon and in conformity with written information
furnished to the Partnership by such Holder or underwriter and stated to be specifically for use
therein, and provided, further, that the Partnership shall not be liable to the extent
that any such loss, claim, damage, liability, expense or action arises out of such person’s
failure to send or give a copy of the final prospectus or supplement to the persons asserting an
untrue statement or alleged untrue statement or omission or alleged omission at or prior to the
written confirmation of the sale of Registrable Securities to such person if such statement or
omission was corrected in such final prospectus or supplement.

          (b) To the extent permitted by law, each Holder will, if Registrable Securities held by such
Holder are included in the securities as to which such registration, qualification or compliance is
being effected, severally and not jointly indemnify the Partnership, each of its directors,
officers and controlling persons, and each underwriter, if any, of the Partnership’s securities
covered by such a registration statement, each person who controls the Partnership or such
underwriter within the meaning of the Securities Act or the Exchange Act or the rules and
regulations thereunder, each other Holder and Other Partner (if and to the extent such Other
Partner has agreed to indemnify the Holders as set forth in this clause (b)) including Registrable
Securities and other securities in the securities as to which such registration, qualification or
compliance is being effected, and each of their officers, directors, members and partners, and each
person controlling such Holder or Other Partner, against all claims, losses, damages and
liabilities (or actions, proceedings or settlements in respect thereof) arising out of or based on
any untrue statement (or alleged

12

 

untrue statement) of a material fact contained in any such registration statement, prospectus,
offering circular or other document, or any omission (or alleged omission) to state therein a
material fact required to be stated therein or necessary to make the statements therein not
misleading, and will reimburse the Partnership and such Holders, Other Partners, directors,
officers, members, partners, persons, underwriters or control persons for any legal or any other
expenses reasonably incurred in connection with investigating and defending or settling any such
claim, loss, damage, liability, action or proceeding, in each case to the extent, but only to the
extent, that such untrue statement (or alleged untrue statement) or omission (or alleged omission)
is made in such registration statement, prospectus, offering circular or other document in
reliance upon and in conformity with written information furnished to the Partnership by such
Holder and stated to be specifically for use therein; provided, however, that the obligations of
each such Holder hereunder shall be limited to an amount equal to the net proceeds to each such
Holder of securities sold as contemplated herein.

          (c) Each
party entitled to indemnification under this Section 7 (the “Indemnified
Party”) shall give notice to the party required to provide indemnification (the
“Indemnifying Party”) promptly after such Indemnified Party has actual knowledge of any
claim as to which indemnity may be sought, and shall permit the Indemnifying Party to assume the
defense of any such claim or any litigation resulting therefrom, including the employment of
counsel reasonably satisfactory to such Indemnified Party, and shall assume the payment of all
reasonable expenses of such defense. Such Indemnified Party shall have the right to employ separate
counsel in any such action or proceeding and to participate in the defense thereof, but the fees
and expenses of such counsel shall be at the expense of such Indemnified Party unless (a) the
Indemnifying Party has agreed to pay such fees and expenses or (b) the Indemnifying Party fails
promptly to assume the defense of such action or proceeding or fails to employ counsel reasonably
satisfactory to such Indemnified Party or (c) the named parties to any such action or proceeding
(including any impleaded parties) include both such Indemnified Party and Indemnifying Party (or an
affiliate of the Indemnifying Party), and such Indemnified Party shall have been advised by counsel
that there is a conflict of interest on the part of counsel employed by the Indemnifying Party to
represent such Indemnified Party and such counsel reasonably determines that it is inappropriate
for such counsel to represent both the Indemnifying Party (or such affiliate of the Indemnifying
Party) and the Indemnified Party (in which case, if such Indemnified Party notifies the
Indemnifying Party in writing that it elects to employ separate counsel at the expense of the
Indemnifying Party, the Indemnifying Party shall not have the right to assume the defense of such
action or proceeding on behalf of such Indemnified Party). Notwithstanding the foregoing, the
Indemnifying Party shall not, in connection with any one such action or proceeding or separate but
substantially similar related actions or proceedings in the same jurisdiction arising out of the
same general allegations or circumstances, be liable at any time for the fees and expenses of more
than one separate firm of attorneys (together in each case with appropriate local counsel) as to
all Indemnified Parties. The failure of any Indemnified Party to give notice as provided herein
shall not relieve the Indemnifying Party of its obligations under this Agreement, unless such
failure to notify materially adversely affects the Indemnifying Party’s ability to defend such
action.

13

 

No Indemnifying Party, in the defense of any such claim or litigation, shall, except with the
consent of each Indemnified Party, consent to entry of any judgment or enter into any settlement
which does not include as an unconditional term thereof the giving by the claimant or plaintiff to
such Indemnified Party of a release from all liability in respect of such claim or litigation. Each
Indemnified Party shall furnish such information regarding itself or the claim in question as an
indemnifying Party may reasonably request in writing and as shall be reasonably required in
connection with the defense of such claim and litigation resulting therefrom.

          (d) If the indemnification provided for in this Section 7 shall for any reason be
unenforceable by an Indemnified Party, although otherwise available in accordance with its terms,
then each Indemnifying Party shall, in lieu of indemnifying such Indemnified Party, contribute to
the amount paid or payable by such Indemnified Party as a result of the losses, claims, damages,
liabilities or expenses with respect to which such Indemnified Party has claimed indemnification,
in such proportion as is appropriate to reflect the relative fault of the Indemnified Party on the
one hand and the Indemnifying Party on the other in connection with the statements or omissions
which resulted in such losses, claims, damages, liabilities or expenses, as well as any other
relevant equitable considerations. The relative fault, in the case of an untrue statement, alleged
untrue statement, omission or alleged omission, shall be determined by, among other things, whether
such statement, alleged statement, omission or alleged omission relates to information supplied by
the Indemnifying Party or the Indemnified Party, and such parties’ relative intent, knowledge,
access to information and opportunity to correct or prevent such statement, alleged statement,
omission or alleged omission. The Partnership and each Holder agree that it would not be just and
equitable if contribution pursuant hereto were to be determined by pro rata allocation or by any
other method of allocation which does not take into account such equitable considerations. The
amount paid or payable by an Indemnified Party as a result of the losses, claims, damages,
liabilities or expenses referred to herein shall be deemed to include any legal or other expenses
reasonably incurred by such Indemnified Party in connection with investigating or defending against
any action or claim which is the subject hereof before the Indemnifying Party assumes the defense
thereof. No person guilty of fraudulent misrepresentation (within the meaning of Section 11(f) of
the Securities Act) shall be entitled to contribution from any person who is not guilty of such
fraudulent misrepresentation.

          (e) Anything to the contrary contained in this Section 7 notwithstanding, no Holder shall be
liable for any indemnification or contribution in excess of the net proceeds received by it from
any sale of Registrable Securities which has been registered hereunder.

     Section 8. Obligations of Holder.

          (a) Each Holder of Registrable Securities included in any registration shall furnish to the
Partnership such information regarding such Holder and the distribution proposed by such Holder as
the Partnership may reasonably request in writing and as shall

14

 

be reasonably required in connection with any registration, qualification or compliance referred
to in this Agreement.

          (b) Each Holder of the Registrable Securities agrees by acquisition of such Registrable
Securities that upon receipt of any notice from the Partnership pursuant to Section 5(e), such
Holder will forthwith discontinue such Holder’s disposition of Registered Securities pursuant to
the registration statement relating to such Registered Securities until such Holder’s receipt of
the copies of the supplemented or amended prospectus contemplated by Section 5(e) and, if so
directed by the Partnership, will deliver to the Partnership (at the Partnership’s expense) all
copies, other than permanent file copies, then in such Holder’s possession of the prospectus
relating to such Registered Securities at the time of receipt of such notice.

     Section 9. Rule 144 Reporting. With a view to making available to the Holders the
benefits of certain rules and regulations of the Commission which may permit a Holder to sell
securities of the Partnership to the public without registration, the Partnership agrees to:

          (a) Use its commercially reasonable efforts to make and keep public information available, as
those terms are understood and defined in Rule 144 under the Securities Act, at all times
following the effective date of the first registration under the Securities Act filed by the
Partnership for an offering of its securities to the general public;

          (b) Use its commercially reasonable efforts to file with the Commission in a timely manner
all reports and other documents required of the Partnership under the Securities Act and the
Exchange Act at any time following registration of any of its securities under the Securities Act
or Exchange Act; and

          (c) So long as a Holder owns any Registrable Securities, furnish to such Holder forthwith
upon request a written statement by the Partnership as to its compliance with the reporting
requirements of Rule 144 (at any time following the Initial Public Offering), and of the
Securities Act and the Exchange Act following registration of any of its securities under the
Securities Act or Exchange Act, a copy of the most recent annual or quarterly report of the
Partnership, and such other reports and documents so filed as a Holder may reasonably request in
availing itself of any rule or regulation of the Commission allowing a Holder to sell any such
securities without registration.

     Section 10. Transfer or Assignment of Registration Rights. The rights granted to the
Investors by the Partnership under this Agreement may be transferred or assigned by such party to a
transferee or assignee of any of such party’s Registrable Securities; provided, that such transfer
or assignment of Registrable Securities was permitted under the Agreement of Limited Partnership of
the Partnership as then in effect; provided, further, that the transferee or assignee of such
rights assumes the obligations of such party under this Agreement. The Partnership must be given
written notice by such party at the time of or within a reasonable time after said transfer or
assignment, stating the name and address of

15

 

said transferee or assignee and identifying the securities with respect to which such
registration rights are being transferred or assigned;

     Section 11.
“Market Stand-off” Agreement.

          (a) Each Holder agrees, if requested by the Partnership and an underwriter of Units (or other
securities) of the Partnership, not to sell or otherwise transfer or dispose of any Units (or
other securities) of the Partnership (other than those registered) held by such Holder during the
period required by such underwriter (up to a maximum of seven days) before and (up to a maximum of
180 days) following the effective date of a registration statement of the Partnership filed under
the Securities Act without the prior consent of such underwriter; provided that such underwriter
requests all other holders of securities of the Partnership and all officers and directors of the
Partnership to enter into similar agreements.

          (b) In the event of an underwritten public offering of Registrable Securities pursuant to
Section 2 hereof, the Partnership agrees, if requested by the underwriter(s) of such offering, not
to sell in the public market any Units (or other securities convertible into or exchangeable or
exercisable for Units) of the Partnership (other than those included in such underwritten public
offering in accordance with this Agreement) during the period required by such underwriter
following the effective date of the registration statement relating to such offering filed under
the Securities Act without the prior consent of such underwriter, provided, however, that such
period shall not exceed 180 days (the “Lock-Up Period”). If the Partnership sells any Units (or
other securities convertible into or exchangeable or exercisable for Units) other than in the
public market during the Lock-Up Period (but excluding any issuances to employees or consultants),
if requested by such underwriter, the Partnership shall require any person to which it sells such
Units to agree to restrictions on the transfer of such securities during the Lock-Up Period
similar to the restrictions agreed to by other holders of securities of the Partnership in
connection with such underwritten public offering.

          (c) Such agreement shall be in writing in a form reasonably satisfactory to the Partnership
and such underwriter. The Partnership may impose stop-transfer instructions with respect to the
shares (or securities) subject to the foregoing restriction until the end of said period.

     Section 12. Governing Law. This Agreement shall be governed in all respects by the
laws of the State of New York, without application of the conflicts of laws principles thereof.

     Section 13. Successors and Assigns; No Third Party Beneficiaries. This Agreement
shall be binding upon, and inure to the benefit of, the successors, assigns, heirs, executors and
administrators of the parties hereto. This Agreement is not intended to confer any right or remedy
on any person who is not a Holder, other than the General Partner or the Partnership.

16

 

     Section 14. Entire Agreement; Amendment. This Agreement constitutes the full and
entire understanding and agreement between the parties and controls and supersedes any prior
understandings, agreements or representations by or between the parties, written or oral, which
conflict with, or may have related to the subject matter hereof in any way. Neither this Agreement
nor any term hereof may be amended, waived, discharged or terminated, except by a written
instrument signed by the Partnership and a majority-in-interest of the Holders. Notwithstanding
the foregoing, no amendment, modification, supplement or waiver of, or departure from this Section
14 shall be effective without the written consent of all the Holders.

     Section 15. Attorney’s Fees. In any action or proceeding brought to enforce any
provision of this Agreement, or where any provision hereof or thereof is validly asserted as a
defense, the successful party shall be entitled to recover reasonable attorney’s fees in addition
to any other available remedy.

     Section 16. Notices, etc. All notices or other communications hereunder shall be in
writing and shall be deemed to have been duly given if delivered personally or sent by telex,
facsimile transmission or telegraphic communication, by recognized overnight courier marked for
overnight delivery, or by registered or certified mail, postage prepaid, addressed to the Investors
as indicated on Schedule 1 attached hereto or at such other address as such persons shall
have furnished to the Partnership in writing and to the Partnership at 1013 Centre Road,
Wilmington, Delaware 19805, fax (904) 281-6145, or such other addresses as shall be furnished by
like notice by such party. All such notices and communications shall,
when telexed (provided the
correct answerback has been received) or sent by facsimile transmission (and receipt thereof is
confirmed) or telegraphed, be effective when telexed, faxed or delivered to the telegraph company,
respectively, or if sent by nationally recognized overnight courier service or if mailed, be
effective when received.

     Section 17. Severability. Whenever possible, each provision of this Agreement shall be
interpreted in such manner so as to be effective and valid under applicable law, but if any
provision of this Agreement is held by a court of competent jurisdiction to be invalid, illegal or
unenforceable in any respect under any applicable law or rule in any jurisdiction, such invalidity,
illegality or unenforceability shall not affect any other provision of this Agreement. If any
provision contained in this Agreement is determined by a court of competent jurisdiction to be
invalid, illegal or unenforceable as written, a court of competent jurisdiction shall, at any
party’s request, reform the terms of this Agreement to the extent necessary to cause such otherwise
invalid provisions to be enforceable under applicable law.

     Section 18. Titles and Subtitles. The titles of the sections, paragraphs and
sub-paragraphs of this Agreement are for convenience of reference only and are not to be
considered in construing this Agreement.

17

 

     Section 19. Counterparts. This Agreement may be executed in any number of
counterparts, each of which shall be an original, but all of which together shall constitute one
instrument.

[REMAINDER OF PAGE INTENTIONALLY LEFT BLANK]

18

 

          IN WITNESS WHEREOF, the parties hereto have executed this Agreement on the day, month and year
first written above.

	 	 	 	 	 	 	 	 	 

	 	 	ALLIANCE CAPITAL PARTNERS, L.P.	 	 
	 
	 	 	 	 	 	 	 	 
	 	 	By:	 	Alliance Capital Partners,
Inc., 
its general partner	 	 
	 
	 	 	 	 	 	 	 	 
	 	 	By:	 	/s/ Robert M. Clements	 	 
	 	 	 	 	 	 	 
	 	 	Name:	 	Robert M. Clements	 	 
	 	 	Title:	 	Chairman and Chief
Executive Officer	 	 
	 
	 	 	 	 	 	 	 	 
	 	 	ARENA CAPITAL INVESTMENT FUND, L.P.	 	 
	 
	 	 	 	 	 	 	 	 
	 	 	By:	 	Arena Equity Partners, LLC	 	 
	 	 	 	 	Its General Partner	 	 
	 
	 	 	 	 	 	 	 	 
	 

	 	 	 	By:

Name:
	 	/s/ Sunil Khanna
 

Sunil Khanna
	 	 
	 

	 	 	 	Title:
	 	Managing Member	 	 
	 
	 	 	 	 	 	 	 	 
	 	 	LOVETT MILLER VENTURE PARTNERS III, 
LIMITED
PARTNERSHIP	 	 
	 
	 	 	 	 	 	 	 	 
	 	 	By:	 	Lovett Miller Venture Fund III, LLC,	 	 
	 	 	 	 	its General Partner	 	 
	 
	 	 	 	 	 	 	 	 
	 	 	By:	 		 	 
	 	 	 	 	 	 	 
	 	 	 	 	W. Scott Miller	 	 
	 	 	 	 	Managing Director	 	 

Amended and Restated Registration Rights Agreement

 

 

IN WITNESS WHEREOF, the parties hereto have executed this Agreement on the day, month and year
first written above.

	 	 	 	 	 	 	 	 	 

	 	 	ALLIANCE CAPITAL PARTNERS, L.P.	 	 
	 
	 	 	 	 	 	 	 	 
	 	 	By:	 	Alliance Capital Partners,
Inc., 
its general partner	 	 
	 
	 	 	 	 	 	 	 	 
	 

	 	 	 	By:

Name:
	 	 
 
Robert M. Clements
	 	 
	 

	 	 	 	Title:
	 	Chairman and Chief
Executive Officer	 	 
	 
	 	 	 	 	 	 	 	 
	 	 	ARENA CAPITAL INVESTMENT FUND, L.P.	 	 
	 
	 	 	 	 	 	 	 	 
	 	 	By:	 	Arena Equity Partners, LLC	 	 
	 	 	 	 	Its General Partner	 	 
	 
	 	 	 	 	 	 	 	 
	 

	 	 	 	By:

Name:
	 	 
 

 

	 	 
	 

	 	 	 	Title:
	 	Managing Member	 	 
	 
	 	 	 	 	 	 	 	 
	 	 	LOVETT MILLER VENTURE PARTNERS III, 
LIMITED
PARTNERSHIP	 	 
	 
	 	 	 	 	 	 	 	 
	 	 	By:	 	Lovett Miller Venture Fund III, LLC,	 	 
	 	 	 	 	its General Partner	 	 
	 
	 	 	 	 	 	 	 	 
	 	 	By:	 	/s/ W. Radford Lovett II	 	 
	 	 	 	 	 	 	 
	 	 	 	 	W. Radford Lovett II	 	 
	 	 	 	 	Managing Director	 	 

 

 

	 	 	 	 	 	 	 	 	 

	 	 	LOVETT MILLER VENTURE FUND II, LIMITED PARTNERSHIP

	 	 
	 	 	By:	 	Lovett Miller Venture Partners II, LLC,	 	 
	 	 	 	 	its General Partner	 	 
	 
	 	 	 	 	 	 	 	 
	 	 	By:	 	/s/ W. Radford Lovett II	 	 
	 	 	 	 	 	 	 
	 	 	 	 	W. Radford Lovett II	 	 
	 	 	 	 	Managing Director	 	 

 

 

SCHEDULE 1

Arena Capital Investment Fund, LP

540 Madison Avenue, 25th Floor

New York, NY 10022

Fax: (212) 885-8585

Lovett Miller Venture Partners III, Limited Partnership

One Independent Drive, Suite 1600

Jacksonville, FL 32202

Fax: (904) 634-0633

Lovett Miller Venture Fund II, Limited Partnership

One Independent Drive, Suite 1600

Jacksonville, FL 32202

Fax: (904) 634-0633

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00183-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00183-of-00352.parquet"}]]