Document:

Exhibit

Exhibit 10.14

Design, Architecture & Engineering, and  
Build-Out Construction Management Agreement
This Design, Architecture & Engineering and Construction Management Contract (“Contract”) is entered at the city of Alajuela, Costa Rica on the 11th day of the month of February of the year 2016, between:
ZONA FRANCA COYOL, S.A., corporate identification card number three- one hundred one- four hundred and twenty thousand five hundred twelve (“CFZ”), registered in the Mercantile Section of the Public Registry under book five hundred sixty, entry ten thousand three hundred and seventy nine, consecutive one, hereon represented by Alvaro Carballo Pinto, personal identity card number one - five hundred and thirty six - six hundred and fifty five, and Huber Andre Garnier Kruse, personal identity card number one- four hundred sixteen- one thousand three hundred forty four, acting jointly and with sufficient authority for the execution of this lease agreement which legal representation is duly recorded in the Mercantile Section of the Public Registry under book five hundred and sixty five, entry eleven thousand five hundred and ninety two, consecutive one, as certified in Schedule One.
for the one part and for the other,
Establishments Labs, S.A., corporate identification card number three- one hundred one- three hundred and sixty nine thousand three hundred and thirty seven (“Establishment”), registered in the Mercantile Section of the Public Registry under book five hundred seventy four, entry sixty six thousand three hundred and seventy nine, consecutive one, hereon represented by Juan Jose Chacon Quirós, with personal identity card number one—eight hundred twenty two-cero cero six, with sufficient authority for the execution of this lease agreement which legal representation is duly recorded in the Mercantile Section of the Public Registry under book two thousand and nine, entry two hundred twenty six thousand seven hundred and forty eight, consecutive one, as certified in Schedule One.
ESTABLISHMENT and CFZ are hereinafter individually referred to as a “Party” and collectively referred to as the “Parties”. The Parties, have agreed to enter into this Contract for the design, engineering, architecture, and construction management services in connection with Phase One of the project, and shall be governed by the following clauses:
Preamble:
1.Whereas, ZFC is the registered owner of a property, located in the “Condominio Horizontal Industrial Comercial con Fincas Filiales Primarias Individualizadas (FFPI) Zona Franca Coyol”(the “Condominium” or “Zona Franca Coyol”), condominium identity number 3-109533883, a condominium registered in the Costa Rican Public Registry, Province of Alajuela, Property Number M-2640- 000, filial lot number twenty six (26), hereinafter the “Property”, registered in the Public Registry Property of Alajuela, Property Number 68517- F- 000.

2.    Whereas, ESTABLISHMENT wishes to complete the Build-Out of the shell building and install the corresponding manufacturing equipment and related improvements, in order to have a fully operational manufacturing facility (the “Facility”), all according to the contractual specifications and plans as agreed upon herein (collectively, the “Project”) for all effects of this Contract.
3.    Whereas, ESTABLISHMENT desires to contract CFZ in order for CFZ to act as the Prime Service Provider of the Project and all other work and services required by this Contract, including without limitation all labor, materials, equipment and services required for the Project (collectively the “Work”) are to be performed and/or provided by CFZ, and the subcontractors hired by CFZ.
4.    Whereas, ESTABLISHMENT intends to hire CFZ on a cost-plus basis whereby CFZ shall perform or cause to be performed the Work for the Cost of Work (hereinafter defined) plus the Prime Services Fee (hereinafter defined) and as described in the Construction Documents, all according to the contractual specifications and plans as agreed upon herein, and as disclosed to CFZ in the scope manual (the “Scope Manual”) provided by ESTABLISHMENT, and attached hereto as Schedule Eight.
5.    Whereas CFZ is interested in performing the Project and all other work and services required by this Agreement, including without limitation all labor, materials, equipment and services required for the Project (collectively the “Works”).
6.    Whereas CFZ is interested in completing all improvements to the Cold Shell Building activities at the sole cost and expense of ESTABLISHMENT as per the Design, Architecture & Engineering and Build-Out Construction Management Agreement.
7.    Whereas ESTABLISHMENT will receive a credit from ZFC for a total amount of US$104,400.00 in relation to the concrete floor of the Cold Shell Building Lease Agreement scope of work; construction of the concrete floor is currently included within this Agreement.
8.    Whereas parties agree that if any ESTABLISHMENT payment to ZFC is delayed for more than thirty (30) days due to an ESTABLISHMENT delay, then ESTABLISHMENT shall start paying Cold Shell Building rent, as per the Lease Agreement, and Rent Commencement Date shall start and be considered as the 31st day of the delay in payment obligations by Establishment to ZFC.
Now therefore in consideration of the mutual promises herein made, and in consideration of the representations, warranties, and covenants herein contained, the Parties have agreed to as follows:
ARTICLE 1 RELATIONSHIP OF PARTIES AND EXTENT OF CONTRACT
1.1    The Parties do not have an employment relationship and do not intend to create a partnership or joint venture between them by this Contract. The relationship created by this Contract 

-2-

shall be that of independent contractor. Neither CFZ nor its employees shall be employees of ESTABLISHMENT for any purpose. CFZ shall be solely responsible for payment of salaries, social charges, insurance and any other employer responsibility related to its employees, and will request this same responsibility from all of CFZ’s subcontractors. ESTABLISHMENT shall be solely responsible for payment of salaries, social charges, insurance and any other employer responsibility related to its employees, and will request this same responsibility from all of ESTABLISHMENT subcontractors and shall fully indemnify CFZ for any related claims or liabilities to which it may become subject or costs which it may incur related to claims by its employees or its Subcontractor’s employees.
1.2    CFZ and ESTABLISHMENT accept the relationship in good faith; fair dealing and trust established by this Agreement and shall cooperate with each other in furthering the parties common interests. CFZ shall exercise its judgment and skill, and shall perform its services in an expeditious and economical manner for the benefit of ESTABLISHMENT. CFZ shall conduct its services in an efficient manner and shall diligently carry out its responsibilities under this Contract.
1.3    It is within CFZ’s discretion to decide whether any Work to be performed by CFZ will be performed by CFZ itself or by a subcontractor or subconsultant of CFZ, provided, however, that CFZ shall not subcontract with any person or entity with whom ESTABLISHMENT objects based on technical or economical basis, which objection may be made in ESTABLISHMENT’s sole discretion. This objection shall be appointed by written notification, and CFZ will remove this objected person or entity within ten days. CFZ shall employ the services of reputable, and well-qualified subcontractors (hereinafter “Subcontractors”) and professional, licensed and well-qualified architects, engineers and other design professionals in connection with the Project (hereinafter “Subconsultants”), only with ESTABLISHMENT prior written consent. All subcontractors and/or subconsultants approved by ESTABLISHMENT prior to the execution of this Agreement do not need further approval, but for any other work or service not included in the Purchase Orders. CFZ shall direct and coordinate the work of its Subconsultants and Subcontractors and shall be responsible for the work performed by them. Notwithstanding anything to the contrary in this Contract, ESTABLISHMENT consent to any Subconsultant or Subcontractor shall not in any way relieve CFZ of any duty, liability or responsibility to ESTABLISHMENT for the services provided by CFZ or any of its Subcontractors or Subconsultants.
ARTICLE 2    REPRESENTATIVES OF PARTIES
2.1    CFZ PROJECT MANAGER: CFZ has designated the person below as its designated representative for general management of this Agreement, (hereinafter referred to as the “CFZ Project Manager”):
Name: Sebastian Acuna
Address: ________________
Phone: ________________
Fax: ________________
E-mail: ________________

-3-

2.2    ESTABLISHMENT PROJECT MANAGER: ESTABLISHMENT has designated the person below as its designated representative for general management of this Agreement, (hereinafter referred to as the “ESTABLISHMENT Project Manager”):
Name: Salvador Dada Santos
Phone: ________________
Email: ________________
ESTABLISHMENT Assistant Site Project Manager
Name : Christopher Morehead
Phone: ________________
Email: ________________
2.3    ESTABLISHMENT hereby provides a special power of attorney (in accordance with article 1256 of the Civil Code of Costa Rica, when required) and authorizes the ESTABLISHMENT Project Manager to act on behalf of ESTABLISHMENT or communicate with CFZ on behalf of ESTABLISHMENT with regards to the Work to the extent within the scope of this Agreement including Change Orders to be made. CFZ shall have the right to rely on such communications from the ESTABLISHMENT Project Manager as if ESTABLISHMENT made them directly.
For clarification purposes, additions and modifications to this Contract, the Build-Out Acceptance Report, and Change Orders are only valid if the ESTABLISHMENT Project Manager has accepted them in writing.
2.4    ESTABLISHMENT may also designate in writing an on “Site Assistant Project Manager”, to help assist the ESTABLISHMENT Project Manager. Therefore, in addition to furnishing the ESTABLISHMENT Project Manager with all information (s)he may require related to the Project, CFZ shall also provide the same information to the Site Assistant ESTABLISHMENT Project Manager. ESTABLISHMENT may designate a replacement Site Assistant ESTABLISHMENT Project Manager upon prior written notice to CFZ, however all decisions shall be executed by the ESTABLISHMENT Project Manager.
2.5    Both parties agree that any changes to their respective site project managers or assistant site project managers shall be communicated to the other party in written prior to (s)he being appointed to the position.
ARTICLE 3    SCOPE OF SERVICES
3.1    CFZ shall provide, or cause to be provided, all design and construction services, labor, and subcontractors, and other facilities and services necessary for the completion of the Works, described in the Contract Documents. CFZ shall perform and complete the Work as described in the Contract and Contract Documents, in a good and workmanlike manner, in accordance with the Contract Documents, and free of any and all liens, encumbrances, stop notices, 

-4-

charges, impositions, garnishments and attachment upon or against the Premises upon which the Project will be located.
3.2    CFZ shall provide to ESTABLISHMENT the Work in a single Phase, which shall be a part of the Work, and shall be performed in accordance with the Scope Manual and the Contract Documents.
3.3    CFZ will guide both Design and Build-Out Construction processes to fulfill ESTABLISHMENT expectations and requirements, as disclosed per the Scope Manual, until Final Completion, Acceptance of Works and hand-over to ESTABLISHMENT.
ARTICLE 4    CFZ’S PRE BUILD-OUT SERVICES
4.1    The Pre Build-Out Services shall include the following services:
4.1.1    CFZ will prepare schematic design and construction documents (the “Construction Documents”), that shall be approved by the Board of Engineers and Architects of Costa Rica (“Colegio Federado de Ingenieros y Arquitectos de Costa Rica”, CFIA), and CFZ shall be responsible for construction permits filing and for making its best efforts in order to obtain such permits. Costs and fees for permits will be ESTABLISHMENT’s obligation, and will be deemed Reimbursable Costs.
4.1.2    Project Organization: CFZ shall take the lead in Build-Out team organization and management, establishing effective systems to facilitate communication, control and coordination between ESTABLISHMENT and subcontractors.
4.1.3    Schedules: Project “Master Schedule”. CFZ shall prepare a master schedule to introduce discipline into the Project’s planning, coordination and monitoring by comprehensively incorporating all the Project’s activities, showing durations, sequence and interdependencies of both design and construction activities. CFZ shall be responsible for providing ESTABLISHMENT with biweekly updates as to the status of the work with respect to the project schedule and a monthly summary report. The current Master Schedule as attached hereto as Schedule Four.
4.1.4    ESTABLISHMENT Approvals:  As per the Project Master Schedule ESTABLISHMENT shall review and approve all ESTABLISHMENT deliverables within the timeframe established in the Master Schedule; any delay on ESTABLISHMENT approvals shall be deemed as an ESTABLISHMENT delay. Final Completion date delivery shall be delayed on the equivalent number of days an ESTABLISHMENT approval was delayed.
Additionally CFZ shall develop with ESTABLISHMENT’s input and subject to ESTABLISHMENT’s approval, the following schedules:
4.1.4.1    Design Schedule & Progress Reviews. CFZ shall also develop a separate but corresponding design schedule focusing on the completion of design documentation. CFZ shall cause the preparation of, and shall review the Build-Out construction drawings, architectural, civil, mechanical, electrical, structural plans and specifications and advise and make 

-5-

recommendations with respect to such factors as possible economies, availability of materials and labor, time requirements for procurement and construction, and project costs. CFZ shall cause the preparation of, and shall review shop drawings and specifications, and coordinate under its best effort to eliminate evident areas of conflict and overlap in the work to be performed by the various trade Subcontractors.
4.1.4.2    “Schedule of Resources”. This schedule shall be used to coordinate the Project’s budget estimate, schedule the anticipated stakeholders of the Project, and chart the planned and actual cash flow and stakeholders required to complete the Project.
4.1.5    Establishing Control Budget Estimate. CFZ will work closely with ESTABLISHMENT Project Manager to confirm the actual scope of the work and assign values to the various components of the Project. In order to avoid increases in cost on this Project, CFZ will utilize the following tools to establish a disciplined approach towards identifying and correcting deviations:
4.1.5.1    “Initial Budget Estimate”. This estimate will forecast Build-Out construction costs on the basis of historical data and local market conditions, as well as any existing bids.
4.1.5.2    “Budget and Cash Flow”. CFZ will review and comment on the Initial Budget Estimate for the entire Project and in parallel to the preparation of the Master Schedule, provide a cash flow study so that ESTABLISHMENT understands the Project’s requirements for cash draws on a monthly basis.
4.1.5.3    Analyze Alternate Systems. Review major systems and components of the Building (e.g. mechanical and electrical systems, exterior wall systems, control systems, and major architectural finishes) to identify potential cost savings and efficiencies. CFZ will consider not only the first installation cost but also maintenance costs for such systems and materials.
4.1.5.4    Any and all schedules, estimates, budgets and Build-Out construction related documents prepared by CFZ will be subject to approval for use on the Project by ESTABLISHMENT Project Manager. ESTABLISHMENT shall provide approval or denial of such schedules, estimates, budgets and construction related documents within five calendar days of receiving such documents.
4.1.6    Bid Packages. Bidding processes may be required for subcontracts (except design services contracts) that exceed US$ 100,000.00. In such cases CFZ shall develop bidders’ interest in the Work, and establish bidding schedules. CFZ shall issue bidding documents approved by ESTABLISHMENT to bidders and conduct pre-bid conferences with prospective bidders. CFZ shall answer questions from bidders and issue the necessary addenda. ESTABLISHMENT shall have the right to attend any Pre-bid conferences and actively participate in these processes.

-6-

CFZ shall receive bids, prepare bid analyses and make recommendations and comment with ESTABLISHMENT the results of the bid for all subcontractors required during the Build-Out Preconstruction stage and the Build-Out Construction stage, in order to ensure compliance with Project requirements, budget and scope. CFZ shall provide ESTABLISHMENT with at least three qualified bids, unless otherwise authorized by ESTABLISHMENT. ESTABLISHMENT shall necessarily choose one of those three bids provided, unless ESTABLISHMENT has a reasonable objection in which case ESTABLISHMENT can direct CFZ to seek new bids, provided that any impact to the Master Schedule will be deemed as an ESTABLISHMENT delay. CFZ will sign a Contract for such works with the accepted contractor in accordance with the terms of the bid subject, however, to the terms and conditions of this Contract.
4.1.7    ESTABLISHMENT shall approve all bidding packages within the time frame provided in the Master Schedule; any delay on such approval shall be deemed an ESTABLISHMENT delay. Final Completion date delivery shall be delayed on the equivalent number of days an ESTABLISHMENT approval was delayed.
4.1.8    Safety Program. CFZ will review and apply requirements for job site safety as provided by its safety manual and applicable local and reasonable international legislation, which will be required in all Subcontractors’ contracts. CFZ will enforce implementation of such requirements, including its incorporation into the packaged bidding process. CFZ will prepare a safety manual for the Project and report followed by periodic monitoring and reporting procedure to be followed throughout the duration of the Project. CFZ shall use reasonable efforts to keep the Site and Works clear o unnecessary obstruction so as to avoid danger to these persons according to the Costa Rican environmental and Labor and Occupational Hazard and Safety and Health laws and by-laws.
4.1.9    Quality Control Plan. CFZ will provide guidelines for a quality control program, incorporating all Subcontractors, separate contractors hired directly by ESTABLISHMENT (if any) and ESTABLISHMENT activities, and will enforce it during the works. CFZ’s approach shall include a review of the Build-Out Construction Documents, shop drawings and specifications. From this review, problems will be identified and discussed with the Subcontractors so that the correct standards and procedures are employed in the bid process. Subsequently, CFZ will carefully monitor the bid process so that there is a complete understanding of the installation techniques and the quality control standards.
4.1.10    Protection of the Environment: CFZ and the Subcontractors shall take all reasonable steps to protect the environment (both on and off the Site) and to limit damage and nuisance to people and property resulting from pollution, noise and other results of his operations. The Contractor shall ensure that emissions, surface discharges and effluent from the Contractor’s activities shall not exceed the values indicated in The Developer’s Requirements, and shall not exceed the values prescribed by applicable Laws. Environmental Management System which shall be based on the UNE-EN ISO 14001: 2000/200 Standard. Contractors shall thereafter implement the Environmental Management System, through the Environmental Program. Under the instructions of CFZ, Contractors shall at all times comply with, and shall cause its Subcontractors to comply with, the Environment Management Procedures and Program. Parties agree that any 

-7-

additional cost related to compliance with Environmental Management System based on UNE-EN ISO 14001 : 2000/200 Standard shall be covered by Establishment.
4.1.11    ESTABLISHMENT may perform periodic audits to verify application of the compliance on every and each of those programs and its results. If, as a result of an audit, ESTABLISHMENT detects any non-conformity to the requirements, ESTABLISHMENT may notify CFZ of such non-conformity. The Contractor shall resolve the instances of non-conformity specified in the audit within a period of fifteen (15) days. Notwithstanding the foregoing provisions of this Clause, CFZ shall at all times remain responsible for making sure all contractors and subcontractors comply with all environmental prevention, mitigation and control measures imposed by Costa Rican Governmental Requirements, and/or SETENA Administration, The Developer’s Environment Supervisor (Regente Ambiental) and other provisions set off in this Contract.
4.1.12    Subcontractors. CFZ shall prepare and award the Build-Out construction contracts necessary to complete the Project (collectively, the “Subcontracts”). CFZ shall negotiate and prepare the biding process for the corresponding contract, and provide ESTABLISHMENT with at least three bids to choose from, unless otherwise authorized by ESTABLISHMENT, and make recommendations as to the one CFZ considers appropriate for the Work. All Subcontracts shall be directly between CFZ and its subcontractors. For purposes of this Contract, Work shall be defined as all of the design services, Build-Out construction, work, labor, materials, equipment, machinery, tools, supplies, services and other items provided by CFZ or subcontracted to the Subcontractors. CFZ shall also advise on the division of the Project into individual Subcontracts for various categories of Work, including the method to be used for selecting Subcontractors and awarding Subcontracts. If multiple Subcontracts are to be awarded, CFZ shall review the Build-Out Construction Documents and make recommendations as required to provide that (1) all requirements for the Project have been assigned to the appropriate Subcontract, (2) the likelihood of jurisdictional disputes has been minimized, (3) the Work of the Subcontractors is coordinated, and proper coordination has been provided for phased construction and (4) The Subcontracts have sufficient guarantees, such as withholding guarantees and performance bonds, in order to ensure fulfillment of Subcontractors’ obligations.
4.1.12.1    CFZ shall receive certificates of insurance from the Subcontractors and hold them. The insurance to be provided by Subcontractors will name ESTABLISHMENT as additional insured.
4.1.12.2    Subcontractors shall have all their personnel fully covered on all the local social security and labour regulations.
4.1.12.3    CFZ shall be responsible for the overall coordination among all of the Subcontractors. CFZ shall also monitor all Project construction to assure that all Subcontractors are acting in compliance with their respective Subcontracts, endeavoring to guard Project against defects;
4.1.12.4    Subcontractors, suppliers and sub-subcontractors of any tier are not intended to be and shall not be third party beneficiaries of this Contract.

-8-

ESTABLISHMENT shall approve all subcontractor offers within the time frame provided in the Master Schedule, any delay on such approval shall be deemed an ESTABLISHMENT delay. Final Completion date delivery shall be delayed on the equivalent number of days an ESTABLISHMENT approval was delayed.
4.1.13    Layout. CFZ will attend meetings with ESTABLISHMENT technical representatives for layout proposal, review layout design alternatives when solicited and collaborate in final freeze of layout design. ESTABLISHMENT shall approve final layout within the time frame provided in the Master Schedule, any delay on such approval shall be deemed an ESTABLISHMENT delay. Final Completion date delivery shall be delayed on the equivalent number of days an ESTABLISHMENT approval was delayed.
4.1.14    Preliminary Architecture and Engineering (A&E) Design based on Schematics. CFZ will review the Scope Manual provided by ESTABLISHMENT for every discipline supplied by ESTABLISHMENT and develop: i) schematic drawings with systems preliminary design, ii) written design brief describing project systems, iii) preliminary equipment dimensioning, iv) description of special systems and room by room plans to review needs for each area, v) including all systems information. This information will become the baseline for the Drawings, Specifications and other documents to be developed by CFZ or its Subcontractors for Build-Out construction purposes. ESTABLISHMENT shall approve all Design packages within the time frame provided in the Master Schedule; any delay on such approval shall be deemed an ESTABLISHMENT delay. Final Completion date delivery shall be delayed on the equivalent number of days an ESTABLISHMENT approval was delayed.
4.1.15    Long lead materials and equipment: CFZ shall coordinate and expedite the ordering and delivery of materials and equipment requiring long lead time. ESTABLISHMENT shall approve all Long Lead item packages within the time frame provided in the Master Schedule, any delay on such approval shall be deemed an ESTABLISHMENT delay. Final Completion date delivery shall be delayed on the equivalent number of days an ESTABLISHMENT approval was delayed.
4.1.16    Special Consultants: CFZ shall assist, retain, select, and coordinate the professional services, special consultants, testing laboratories and surveyors required for the Project, including all those Engineers and Architects not specified as part of CFZ’s staff for the Project. None of the Special Consultant’s prices or fees are included in the CFZ’s Build-Out Construction Management Fee. Therefore they will be deemed Reimbursable Costs. ESTABLISHMENT Project Manager, shall authorize any special consultants not previously approved. Fees of Special Consultants that are hired directly by ESTABLISHMENT will not be included as part of the Contract Sum, and CFZ will not charge the Build-Out Construction Management Fee established below regarding the invoices presented by these special consultants hired by ESTABLISHMENT.
4.1.17    Permits: CFZ shall file, and make its best efforts in order to obtain Build-Out construction permits in a timely manner in accordance with the Master Schedule. CFZ shall ensure that all applicable assessments and fees have been paid. ESTABLISHMENT shall assist CFZ in the 

-9-

filing of documents required for the approvals of governmental authorities having jurisdiction over the Project. Permits will be deemed Reimbursable Costs.
The overall schedule of the project is subject to the permits being approved. If permits are not approved prior to the start of construction despite CFZ’s reasonable efforts to obtain such permits and provided CFZ has diligently and proactively processed such permits, the project schedule and budget will be reassessed to reflect not more than a day-for-day delay and actual costs resulting from such delay.
If any such delays are caused by, or related directly to the design, the condominium, or the execution of the works, such delays shall not be the responsibility of ESTABLISHMENT.
4.1.18    CFZ Deliverables: CFZ shall provide the following deliverables by the conclusion of the Build-Out Pre Construction Stage:
4.1.18.1    Conduct schematic design review.
4.1.18.2    Construction documents from all disciplines.
4.1.18.3    Establish the Master Schedule including major milestones and decision dates.
4.1.18.4    Develop an Initial Budget Estimate based on the Schematic Documents.
4.1.18.5    Create a site safety plan.
4.1.18.6    Establish a procurement strategy including long lead items and equipment purchases.
4.1.18.7    Preparation of and assistance in the development of all bid packages and award of Subcontracts applicable at the time.
4.1.18.8    Prepare comparison chart of Subcontractors offers and make recommendation.
4.1.18.9    Review layout and Scope Manual prepared by ESTABLISHMENT.
4.1.18.10    Design development of Architecture and Engineering documents.
4.1.18.11    Permit filing, tracing of such filings and presenting additional information or clarifications when required.

-10-

4.1.19    ESTABLISHMENT Deliverables: ESTABLISHMENT shall provide the following deliverables for the Build-Out Pre Construction Stage:
4.1.19.1    Secured funds for Build-Out construction.
4.1.19.2    All due payments to CFZ by ESTABLISHMENT related to the Build-Out Pre-Construction Stage must have been completed as per the amounts and dates specified in this Contract. CFZ will not start the Build-Out Construction stage unless all due payments have been honored.
4.1.19.3    Approval of all Schematic Design and Construction Documents. After approval by ESTABLISHMENT all documents will be “freezed” and any changes to plans, blue prints, specifications, or any other document shall be made through the Change Order process established on this Contract.
4.1.19.4    Finance and accounting structure in place to support payment process between CFZ and ESTABLISHMENT.
4.1.19.5    CFZ will have the right to refuse the start of the Build-Out Construction Stage if any of the above conditions are not met by ESTABLISHMENT. ESTABLISHMENT shall approve all deliverables within the time frame provided in the Master Schedule, any delay on such approval shall be deemed an ESTABLISHMENT delay. Final Completion date delivery shall be delayed on the equivalent number of days an ESTABLISHMENT approval was delayed.
ARTICLE 5    CFZ’S SERVICES IN RELATION TO BUILD-OUT CONSTRUCTION AND GENERAL CONTRACTING
5.1    The “Build-Out Construction Stage” shall start with a proper Commencement of Works pursuant to ESTABLISHMENT completion of deliverables established in section 4.1.15, emission of written start order and acceptance by CFZ, and end upon Final Completion by CFZ and Acceptance by ESTABLISHMENT. CFZ shall provide the following Build-Out Construction Stage Services to ESTABLISHMENT for the Build-Out Construction Stage:
5.1.1    During the Build-Out Construction stage of the Project, CFZ will provide the following Construction related services as well being directly responsible to ESTABLISHMENT for the actual performance of the Work, provided ESTABLISHMENT fulfills payment:
A.    Scheduling
B.    Budget and Cost Control
C.    Supervision of Subcontractors
D.    Cash Flow Control, Accounting and Exemptions

-11-

E.    Job Closeout
F.    Design Development and Specifications
G.    Construction Documents
H.    Multidisciplinary Inspection
In addition, all Construction Documents complement each other, and anything required in one shall be binding for all. If there are any ambiguities or discrepancies, the following hierarchical order as to their prevalence shall apply:
a)    This Contract, including executed changes to this agreement;
b)    Addenda to this Agreement; and
c)    Construction Documents.
Furthermore, in each specialized field, the specialized plans shall prevail over the general ones, the drawings at larger scale shall prevail over those of lower scale, and the dimensions specified shall prevail over measurements at scale.
The following is a further description of the full scope of CFZ’s Build-Out Construction Stage Services.
5.2    Work performed by Subcontractors. CFZ will be responsible for ensuring that all of its Subcontractors act in accordance with all obligations and regulations that are contained in or are derived from this Contract and the other Construction Documents including, without limitation, the General Conditions. CFZ shall request from all Subcontractors guarantees for all Work, in the amount and terms consistent with CFZ’s obligations set forth in this Contract. In the event that ESTABLISHMENT terminates this Contract due to a breach of CFZ’s obligations contained herein, CFZ agrees to assign to ESTABLISHMENT, at ESTABLISHMENT request, it rights under any or all subcontracts for the Work and/or all rights it may have against all Subcontractors related to warranties and guaranties provided on the Work once all due payments to CFZ by ESTABLISHMENT have been completed.
5.3    Scheduling: A vital management tool of CFZ on the Project will be the Master Schedule and Detail Schedules. Recognizing the importance of the scheduling process, CFZ will utilize the following tools to monitor and control the rate and sequence of Work. ESTABLISHMENT shall approve all deliverables within the time frame provided in the Master Schedule; any delay on such approval shall be deemed an ESTABLISHMENT delay. Final Completion date delivery shall be delayed on the equivalent number of days an ESTABLISHMENT approval was delayed.
5.3.1    Master Schedule: Master Schedule will be developed during Build-Out preconstruction stage, and refers to a realistic overall schedule outlining in general terms all 

-12-

activities from the earliest feasibility studies to final construction completion of all phases of the Project. This Master Schedule is an overall schedule of the total Project, and forms the basis for subsequent scheduling.
5.3.2    Detail Schedules: During construction the Master Schedule is broken down into more detailed components. These Detail Schedules monitor and manage the day-to-day construction activities while still being tied back to Master Schedule.
5.3.3    CFZ shall update all schedules monthly using the schedules provided by the Subcontractors, labor and equipment, and shall incorporate the activities of the Subcontractors on the Project, activity sequences and durations, allocation of labor and materials, processing of shop drawings, product data and samples, and delivery of products requiring long lead time and procurement. CFZ’s responsibility is to assemble this information and present it to ESTABLISHMENT for review. CFZ shall update and reissue the Master Schedule as required to show current conditions. If an update indicates that the previously approved Master Schedule is showing any delay, CFZ will perform corrective actions, unless the delay is due to ESTABLISHMENT actions for failure to perform such actions, in which case, if additional funds or resources are justified and required due to such delay, the established Change Order procedure will be followed.
5.3.4    CFZ shall prosecute and perform the Work with the utmost dispatch consistent with good workmanship and agrees to complete the Work in accordance with the Master Schedule provided that no Force Majeure, Acts of God or any of the causes set in Articles 5.3.4.1 through 5.3.4.5 occur during the Build-Out Construction Stage. It is agreed that time is of the essence of this Contract and of all the provisions thereof. CFZ shall be entitled to have an extension of the Master Schedule if and to the extent that completion of the whole Project is delayed solely by any of the causes set forth in Articles 5.3.4.1 through 5.3.4.6.
5.3.4.1    If rain on the construction site is documented to have caused an inability to conduct Build-Out construction, using reasonable and normal construction procedures and standards.
5.3.4.2    A Force Majeure event. As used in this Contract “Force Majeure” shall mean any event which (i) cannot be reasonably anticipated or controlled, (ii) which significantly affects contracted performance, and (iii) is not reasonably subject to the control of the party invoking it, whether (A) related to nature, including but not limited to fire, lightning, earthquake, or windstorm, flood or the like, or (B) related to man, such as but not limited to unforeseen adverse political or economical events, civil insurrection, war, strikes or other labor disturbances provided such strikes or labor disturbances affect the Costa Rican construction industry generally, or changes in the law or third party actions which, in both cases, could not have reasonably been foreseen.
5.3.4.3    Any delay, impediment or prevention caused by ESTABLISHMENT, its representatives, its contractors or vicarious agents (other than CFZ and CFZ Subcontractors), and/or ESTABLISHMENT visitors, including delays caused by Change 

-13-

Orders given by ESTABLISHMENT, to the extent such delay has been notified in written to ESTABLISHMENT, or the applicable Change Order as more fully set forth in Article 6, as well as delays due to failure of ESTABLISHMENT to respond to CFZ’s inquiries, or to provide approvals, or delays caused due to lack of payment (such delays, a “ESTABLISHMENT Delay”).
5.3.4.4    Unforeseen delays due to governmental or the corresponding authority decisions not attributable to CFZ’s acts or omissions, including delays caused by the terms taken by the corresponding institutions and authorities in order to grant any permits required for the implementation of all planning, provided that CFZ has initiated and proceeded diligently with the necessary filings and has provided all the required information as requested by authorities.
5.3.4.5    Delays by ESTABLISHMENT in making corresponding payment within the terms provided in the Payment Schedule, which delay exceeds ten (10) calendar days.
5.3.4.6    An Onerous Event. As used in this Agreement “Onerous Event”shall mean any action of, or failure to act by, the government of Costa Rica or any relevant authority (including, without limitation, (a) any change (whether by the introduction, modification or application of any law, decree or regulation or otherwise) after the Effective Date in the legal framework in effect, (b) any embargo, expropriation, nationalization or act of eminent domain not constituting an expropriation, (c) any devaluation or adverse change in the currency of Costa Rica, (d) any revocation or other withdrawal of any consent other than in accordance with the provisions thereof or any agreement relating thereto or in accordance with the legal framework in effect, and (e) any failure by the government of Costa Rica or any relevant authority to act in accordance with the legal framework in effect, which action or failure to act adversely changes the legal, economic or commercial position of the Project, CFZ or any Subcontractor, from what it was on the Effective Date or from what it is or what it would have been but for such action or failure to act.
CFZ shall, within a five (5) working days period, notify ESTABLISHMENT in writing of any delays and its impact towards the Delivery Date in the Master Schedule caused by ESTABLISHMENT or its separate contractors, as well as any event that would permit an extension of time. If CFZ is delayed in the performance of CFZ’s Work by reason of a ESTABLISHMENT Delay (including delays in approvals of Change Orders, plans, etc.), then, subject to CFZ’s compliance with the foregoing notice provision, the Hand Over Date which is affected by such ESTABLISHMENT Delay shall be extended accordingly.
Any delays in the performance of CFZ’s Work caused by changes in CFZ’s Work requested by ESTABLISHMENT (“ESTABLISHMENT Changes”) and not related to any negligence or breach of contract by CFZ shall be deemed to be a ESTABLISHMENT Delay.
5.4    Cost Control: CFZ’s cost control process can be implemented to monitor actual construction costs versus the accepted budget. Beginning with initial contract awards, the cumulative amount of committed funds is carefully monitored. The data is compiled and continuously compared to the approved estimate and updated by means of the monthly Budget Execution Report. CFZ or a Subcontractor, as determined among such parties, shall be responsible for all non-approved by 

-14-

ESTABLISHMENT cost-overruns, if any, of the Subcontractors, unless such excess costs have been approved by ESTABLISHMENT pursuant to a Change Order.
5.4.1    Construction Budget: An Initial Estimate Budget will be created by CFZ in the Build-Out Preconstruction Stage, which shall be updated as provided for the schedules in Article 5.3 above. Each additional budget will be based on the documents issued at that time and will be compared with the Initial Estimate Budget or to the subsequent budget and the Contract Sum. The next budget will be based on the Build-Out design development documents. CFZ will develop an itemized budget estimate and will assist in the subcontractor availability in the local market. Each additional budget shall be approved in writing by ESTABLISHMENT.
5.4.2    “Budget Execution Report”: A contract cost report is issued monthly summarizing the current financial status of the Project. The report shows the approved budget and notes all variances from that estimate due to changes initiated by ESTABLISHMENT or other required modifications. CFZ shall prepare the Budget Execution Report. The Budget Execution Report shows changes in two categories: “approved,” i.e. a Change Order has been approved by ESTABLISHMENT; “potential,” i.e. change estimate has been submitted and awaits approval by ESTABLISHMENT or an approximate estimate has been developed and submitted as an early warning system for identifying potential cost. CFZ shall develop cash flow reports and forecasts for the Project and advise ESTABLISHMENT as to variances between actual and budgeted or estimated costs. Acceptance and approval of all cash flow reports and forecasts prepared by CFZ will be subject to ESTABLISHMENT approval.
5.4.3    Payment Application and Change Order Procedures: CFZ shall submit Payment Applications for all Work performed, whether performed by itself or by Subcontractors and work with ESTABLISHMENT to establish a monthly Application for Payment procedure, including supporting documentation. CFZ will also develop a detailed Subcontract Change Order procedure control plan that shall apply to CFZ and all Subcontracts. As part of such plan, CFZ shall review requests for changes, assist in negotiating Subcontractors’ proposals, submit recommendations to ESTABLISHMENT, and, if approved by ESTABLISHMENT, prepare documentation that incorporates the modifications to the applicable Subcontract. All applications for progress and final payment to Subcontractors will be sent to CFZ by Subcontractors, who shall review them and if approved, request final payment from ESTABLISHMENT.
5.4.4    According to the version of the Initial Budget Estimate, negotiated between the parties as of the date of this contract execution, the total Initial Budget Estimate Construction Cost of Work represents a total amount of five million eight hundred twenty eight thousand and ninety dollars with fifty three cents, legal tender of the United States of America (US$ $5,828,820.00). All payments based on latest Initial Budget Estimate shall be made by ESTABLISHMENT to CFZ according to approved Cash Flow, as shown on Schedule Eleven. Initial Budget Estimate doesn’t include the concrete floor credit from Lease Agreement.
5.4.5    Review of Applications for Payment from Subcontractors. Within seven days after receipt of a Subcontractor’s payment application, CFZ shall review the payment application and all supporting documentation for the amounts claimed due to be in compliance with 

-15-

the applicable Subcontract and this Contract, and if CFZ approves such payment application CFZ shall forward to ESTABLISHMENT an equivalent CFZ Payment Application in accordance with the terms of this Contract.
5.4.5.1    For each Payment Application the CFZ Project Manager will review the Master Schedule and detailed work activities and any other documents necessary to determine the percent complete and the value of the installed work in accordance with the total cost of such work, with ESTABLISHMENT Project Manager; provided, any such review or failure to review by ESTABLISHMENT Project Manager shall not release CFZ or ESTABLISHMENT of its obligations, representations and warranties with respect to such Payment Application.
5.4.5.2    ESTABLISHMENT’s Project Manager shall have a term of three calendar days to approve the Payment Application. Once the Payment Application has been approved, CFZ will submit the corresponding invoices to ESTABLISHMENT and ESTABLISHMENT shall pay for such invoices within the following ten (10) calendar days after an acceptable invoice was submitted. The monthly payment will not be a fixed amount but will depend on deliverables and Work completed through the date of Payment Application.
All invoices and Payment Applications shall be submitted via e-mail as follows:
Attention:
Name: Jimmy Villalobos
Email: ________________
5.4.5.3    ESTABLISHMENT shall make payments of the amounts due to CFZ in accordance with the Payment Application and as provided herein.
5.5    Subcontractor Supervision and Responsibility. CFZ shall be fully responsible for all aspects of any Subcontractor’s performance of any part of the Work that have been contracted directly by CFZ. CFZ shall accomplish this through the effectiveness of the following:
5.5.1.1    Meetings: CFZ will coordinate and manage coordination meetings.  CFZ will review the schedule, workmanship quality and cost.
5.5.1.2    Field Supervision: CFZ will maintain field staff to monitor and coordinate all field construction activities. Such staff will schedule and conduct meetings with the Subcontractors to control the supply and utilization of their manpower, materials and equipment they are responsible for quality control and enforcing the Project Specific Safety Program and Quality Programs. CFZ will observe all testing performed by the Subcontractors as required to verify conformance with contractual Subcontracts for each aspect of the project including start-up and check out of utilities, operational systems and equipment.
5.5.1.3    CFZ shall arrange and coordinate for the Subcontractor’s performance of the delivery, storage, protection and security of materials, systems and equipment 

-16-

that are a part of the Project until such items are incorporated into the Project. CFZ agrees to hold harmless ESTABLISHMENT with respect to any loss of or damage to such to such materials, systems and equipment was due to CFZ’s or Subcontractor’s negligence or willful misconduct.
5.5.1.4    CFZ shall maintain on a current basis at the Project site records of all Subcontracts, Build-Out Construction Documents, drawings, specifications, addenda, Change Orders and other modifications, samples, purchases, materials, equipment, maintenance and operating manuals and instructions, and other construction-related documents, including all revisions and all the records under the CFIA Bylaws;
5.5.1.5    CFZ shall answer all questions for interpretation of the Build-Out Construction Documents.
5.5.1.6    Monthly Progress Report: CFZ will be submitting a monthly Project update report that will include:
		
	•
	Executive Summary.

		
	•
	Progress Pictures.

		
	•
	Permit Log Update.

		
	•
	Master Schedule Update including Work completed for the period.

		
	•
	Long-lead Items Status.

		
	•
	Design Log Update.

		
	•
	Quality Control Report.

		
	•
	Budget update including cash-flow and forecast reports, and cumulative total of the cost of the Work to date including compensation of CFZ and Reimbursable Costs (authorized and claimed), if any, and all sums paid to Subcontractors, as well as the amounts pending.

		
	•
	Reasonable critical Information required by ESTABLISHMENT.

5.5.2    Quality Control: CFZ’s Quality Control Program starts during the Build-Out Preconstruction Stage and continues through the entire life of the Project. During the design period, CFZ will review Subcontractor shop drawings and specifications, and other submittals and documents prepared by the Subcontractors (“Submittals”) for conformance to the applicable Subcontract and Build-Out Construction Documents. CFZ shall identify and document any problem areas and have them solved with Subcontractors, and confirm that Subcontractor understands the installation techniques and the quality control standards that will be expected and enforced. The first operation of any new trade is closely monitored to assure that the expected level of workmanship is established from the outset. A day-to-day check of the Work is made by the appropriate staff of CFZ 

-17-

to guarantee that the level of consistency is maintained. CFZ shall monitor and review all Work for conformance to the Build-Out Construction Documents. Cost of laboratory tests is not included in CFZ’s Build-Out Construction Management Fee.
5.5.2.1    CFZ shall assist in scheduling and monitor of the sequence of the Work in accordance with the Build-Out Construction Documents and the latest approved Master Schedule. The Master Schedule and all budgets shall be approved in written by ESTABLISHMENT after review and comment by CFZ. CFZ shall inform ESTABLISHMENT in advance of any event that may create a delay in the Work or increase in any Project budget. Upon informing ESTABLISHMENT of such an event, CFZ shall assist the Subcontractors in developing cost effective solutions to such an event for ESTABLISHMENT review and approval. CFZ and the Subcontractors shall perform all corrective work in accordance with ESTABLISHMENT recommendation on any remedial plan.
5.5.3    Cash Flow control, exemptions and accounting:
5.5.3.1    Cash Flow Control: CFZ shall communicate with all Subcontractors at the Project in regard to payment procedures. CFZ shall establish a monthly payment application procedure consistent with the payment provisions of this Contract.
5.5.3.2    Exemptions: CFZ is a Free Trade Zone Regime beneficiary, and as part of its benefits it is exempted of import duties and of local sales taxes. CFZ shall, as process facilitator, acquire all local materials and services, and import and process materials and/or equipment that will be used or installed in connection with Project, to the fullest extent permitted by PROCOMER and applicable law, until such items can be transferred to ESTABLISHMENT (if applicable), under the proper customs procedures. CFZ will transfer all exempted works, materials and equipment to ESTABLISHMENT at the end of Build-Out construction of the Project if applicable.
5.5.3.3    Accounting: CFZ shall keep all construction accounting and control of the exemptions in order to help ESTABLISHMENT to take full advantage of the free zone exemptions and at the same time have a direct control of the Project disbursements and cash flow. CFZ shall not be liable for any lost or rejected exemption in materials or inventory by the respective legal authorities, provided it has requested such exemptions diligently.
5.6    CFZ shall provide the following deliverables by the conclusion of the Build-Out Construction Stage to ESTABLISHMENT:
5.6.1.1.1    As built drawings (printed and/or digital versions)
5.6.1.1.2    Required documents for Commissioning.
5.6.1.1.3    Operations and Maintenance Manuals.
5.7    Design Development and Specifications: CFZ will develop the design based on approved layout and scope manual provided by ESTABLISHMENT.

-18-

5.7.1    Construction Documents: Design Architects and Engineers will prepare detailed construction drawings of all systems, final specifications, final equipment selections, including all information to allow Subcontractors and vendors to price the work. Shop drawings and other installation drawings are responsibility of the Subcontractors but if any claim shall be filed against such Subcontractor, CFZ will coordinate such filing with ESTABLISHMENT as required.
5.8    CFZ’S Authority: CFZ shall advise and consult with ESTABLISHMENT during the performance of its Build-Out Construction phase of the Work. CFZ shall have no authority to act on behalf of ESTABLISHMENT except to the extent of authorizations explicitly granted pursuant to this Contract. In no event shall CFZ be considered an agent of ESTABLISHMENT or be expressly authorized to enter into contacts on behalf of ESTABLISHM ENT.
5.9    Access to the Work: The Subcontractors and CFZ shall provide ESTABLISHMENT access to the Work in preparation and progress wherever located.
5.10    Inspection: ESTABLISHMENT’s Personnel shall at all reasonable times: have full access to all parts of the Site and to all places, and during production, manufacture and construction (at the Site and, to the extent specified in the Contract, elsewhere), be entitled to examine, inspect, measure and test the materials and workmanship, and to check the project progress.
ARTICLE 6    CHANGE ORDERS
6.1    Alterations, additions or deductions may be made in the Work herein, but said alterations; additions or deductions may only be made by means of a Change Order.
6.1.1    ESTABLISHMENT may request a Change Order in writing to CFZ, in the form attached hereto as Schedule Six, “Change Order Request”. Such Change Order Request shall include a description of the required work and technical specification of fixtures, furniture and equipment (FF&E) to be installed, if applicable.
6.1.2    CFZ may request a Change Order in writing to ESTABLISHMENT, in the form attached hereto as Schedule Six, “Change Order Request”. Such Change Order Request shall include a description of the required work and technical specification of fixtures, furniture and equipment (FF&E) to be installed, if applicable.
6.2    Modifications to the Master Schedule including extensions that impact the Build-out Substantial Completion may only be made in accordance with the terms of the Contract, and only by means of a Change Order.
6.3    CFZ shall submit to the ESTABLISHMENT Project Manager for his approval all Change Orders, in the form attached hereto as Schedule Six, and including the following information:
6.3.1    Soft cost which shall include, but are not limited to:
		
	(a)
	Custom clearance fees;

-19-

		
	(b)
	Insurance (costs of premiums for all bonds and insurance permit fees, and sales, use or similar taxes to the extent applicable to the Change Order);

		
	(c)
	Permits, temporary installations, quality control, utilities for Build-Out construction, along with printed materials and other equivalent reasonable soft costs actually incurred.

6.3.2    Direct Build-Out Construction cost from Subcontractors which shall include, but not limited to:
		
	(a)
	Labor (including social security, old age and unemployment insurance, fringe benefits required by agreement or custom, and workers’ compensation, as well as additional costs of supervision and field office personnel directly attributable to the Changes Order);

		
	(b)
	Materials, tools and equipment (including supplies and equipment, cost of transportation thereof and taxes thereon, whether incorporated or consumed, as well as rental costs of machinery and equipment exclusive of hand tools, whether rented from CFZ or others, provided however that (i.a) if such items are rented from CFZ, the rental charges shall not exceed the average amount which would be charged by unrelated third parties engaged in the business of renting such machinery and equipment, for which a sample of three companies may be used; and (i.b) ESTABLISHMENT shall only be charged for the period of rental during which the equipment has been used in the construction activity, which shall include the times of activity, support and stand by times;

		
	(c)
	Consumables, subcontracts, FF&E, fleets, and contingencies;

6.3.3    Each Change Order shall include CFZ’s Build-Out Construction Management Fee of thirteen percent (13%) of the total Cost of Work incorporated in the Change Order pursuant to Article 6.1.2 or 6.3.2.
6.3.4    CFZ Hourly Services. As an exception to sections 6.3.2 and 6.3.3 above, CFZ will perform the following services subject to a Change Order, and CFZ will charge an hourly service fee to be quoted in advance, which will not include Build-Out Construction Management Fee, nor the costs established in such sections:
a)    Changes to the Final Drawings, Schematic Designs and Scope Manual, requested by ESTABLISHMENT after they have been approved by ESTABLISHMENT, in all design portions, unless these changes are corrections on failures of the Designs. The Works portion of this Change Order will be charged as established in Articles 6.3.1 to 6.3.3 above.

-20-

b)    Changes to Build-Out Pre Construction Stage Deliverables after they have been delivered. including when changes are required due to subdivision of the Work in phases. The Construction Works portion of this Change Order will be charged as established in Articles 6.3.1 to 6.3.3 above.
6.3.5    Time of completion and its impact, if applicable, on the overall Master Schedule, in case the Change Order affects the critical path of the Project.
6.3.6    Change Order Payment Schedule: Change Orders will be paid by ESTABLISHMENT in accordance with the terms of the applicable Change Order and otherwise in accordance with the payment provisions of the Contract. There shall be no retentions to any Change Order.
6.4    Change Orders for Work to be performed by Subcontractors with a total price of Fifty Thousand dollars (US$50,000.00) or more, shall be based on offers from at least three bids, unless otherwise authorized by ESTABLISHMENT, after having performed an appropriate bidding process as per Article 4 herein. ESTABLISHMENT shall authorize one of the three offers, unless ESTABLISHMENT has a reasonable objection in which case ESTABLISHMENT can direct CFZ to seek new bids; in which case any resulting delay due to ESTABLISHMENT instructions will be contemplated in the Master Schedule. Change Orders for Work with a total cost inferior to Fifty Thousand dollars (US$50,000.00) do not require a bidding process however they do require a third party firm offer.
6.5    ESTABLISHMENT agrees, that the final cost of the Change Order once performed, may be higher than the budgeted cost in a maximum amount of five per cent (5%) of the original budgeted cost; as a result ESTABLISHMENT agrees to pay the difference between the budgeted amount and real cost as long as such cost difference does not surpass five per cent (5%)
6.6    ESTABLISHMENT will have three (3) working days to accept or reject in written the Change Order proposal given by CFZ. CFZ will only perform Change Orders with ESTABLISHMENT written confirmation and acceptance from ESTABLISHMENT Project Manager. However if ESTABLISHMENT does not respond by accepting or denying a Change Order, or if ESTABLISHMENT denies such Change Order, CFZ shall continue with the Work as intended as per the Build-Out Construction Documents.
6.7    All Work shall be made in compliance with the Condominium by-laws, park regulations, and construction codes effective in Costa Rica, and all applicable legal requirements.
6.8    On the Final Completion of the Project or earlier termination of this Contract, CFZ shall transfer all original documents related with the performance of the Work and the Project to ESTABLISHMENT (if applicable), as well as copies of all original invoices and contracts used for performing the Work, and all alterations, additions or deduction thereto CFZ the original invoices and contracts, for a period of five (5) years after said Work is performed if applicable.
6.9    Changes to the Final Drawings, Schematic Designs and Scope Manual, requested by ESTABLISHMENT after they have been approved by ESTABLISHMENT, will also be performed 

-21-

subject to a Change Order, however, in these cases, CFZ will charge an hourly fee (based on attached hourly fees) for the services in the design portion of the Change Order to be quoted in advance. The Works portion of the Change Order will be charged as established above.
ARTICLE 7    WORK CLOSE OUT— HAND OVER DATE
7.1    CFZ shall deliver the Project when it is “substantially completed”, as established in the Project Master Schedule under Schedule Four, in accordance with the requirements of this Contract (except any Punch List items), the Scope Manual and the Building Layout provided by ESTABLISHMENT and as of the Final Engineering Drawings provided by CFZ and approved by ESTABLISHMENT (such date, the “Hand Over Date”). “Build-out Substantial Completion” shall be defined as the point at which CFZ has completed each part of the Project at least ninety five percent (95%) completion so long as the Facility is ready for its intended use at full capacity, subject to any part of the Work that is not required to be completed as part of Build-out Substantial Completion pursuant to a Change Order that has been mutually agreed to be executed thereafter due to build-out or operations schedule requirements.
7.2    CFZ shall deliver the Facility to ESTABLISHMENT in a clean and proper state, free of any waste, and any other left over material, and ready for ESTABLISHMENT’s separate tool and equipment installation.
7.3    At the Hand Over Date, ESTABLISHMENT Project Manager and CFZ Project Manager shall inspect the Building and review the Build Out Acceptance Report which shall include a list which sets forth any pending Work, (hereinafter the “Build-out Punch List”) as well as the timing of their final delivery, as deemed appropriate. In case of acceptance, ESTABLISHMENT Project Manager and CFZ Project Manager shall sign the Acceptance Note included in the report and CFZ will provide an invoice of all amounts owed to CFZ for payment within the following thirty (30) calendar days. In case of dispute regarding Build-out Substantial Completion, parties will have to solve such dispute, as indicated in Section 18. The Build-out Acceptance Report will be submitted to ESTABLISHMENT by CFZ for its acceptance on the date of inspection.
7.4    The Hand-Over date shall be the date on which all warranty periods commence and the date on which all risks pass from CFZ to ESTABLISHMENT.
7.5    Within thirty (30) days after the Hand-Over Date, CFZ shall complete the Build-out Punch List (unless any such items were explicitly agreed to be completed within a shorter or longer period), supply ESTABLISHMENT with a set of documents related to the Building, including As Built plans, a confirmed list of all Subcontractors, design calculations, all operational documents and manuals of all equipment installed, as provided by vendors. Upon the satisfaction of the foregoing, the Project shall be deemed to have achieved “Final Completion”, and CFZ will provide an invoice of all amounts owed to CFZ (including Retentions if any), for payment within the following thirty (30) calendar days. CFZ shall also deliver any remaining undelivered formal contract termination (in the form attached as Schedule Seven (the “Subcontractors Termination”) from all subcontractors that have performed work related to the Project.

-22-

7.6    Turnover: CFZ will organize and direct the education of the Facility’s personnel in the operation and maintenance of the new Facility. CFZ will also assist the facilities personnel in evaluating systems performance in the critical break-in periods where required. Turnover obligations shall not interfere with Work Close Out however CFZ shall cooperate with ESTABLISHMENT as required.
7.7    If the Build-out Substantial Completion does not take place as required in the Master Schedule (as duly changed), CFZ shall pay to ESTABLISHMENT as liquidated damages a fixed and sole compensation for damages or losses due to delay, an amount equal to zero point zero fifteen per cent (0.015%) of the unpaid amount to CFZ of CFZ fees for every additional day of delay for the first seven days of delay; if such delay continues starting on the 8th day of delay, CFZ shall pay an additional zero point zero twenty five percent (0,025%) of the unpaid amount to CFZ of CFZ fees for every additional day of delay for next seven days of delay, if such delay continues starting on the 15th day of delay, CFZ shall pay an additional zero point zero four percent (0,4%) of the unpaid amount to CFZ of CFZ fees for every additional day of delay until de Substantial Completion date.. Additionally, ESTABLISHMENT shall be entitled to all economic fines that CFZ might recover from all subcontractors due to a subcontractor delay as per the corresponding contract; CFZ shall not be held accountable for any fine not recovered from a subcontractor. The maximum damages for any claims under this Contract, whether caused by CFZ or any Subcontractor shall be limited to the amount of two hundred thousand dollars (US$200.000,00). CFZ acknowledges and agrees that CFZ’s sole compensation and remedy for any ESTABLISHMENT Delays shall be repayment of direct costs as agreed to by the Parties pursuant to a Change Order in accordance with the Change Order procedures contained in this Contract. The Parties warrant and acknowledge that they will not file any lawsuits or claims to recover additional amounts from the delaying Party due to delays. In no event shall either party be responsible to the other for consequential damages or loss of profit.
7.8    If failure to achieve the Work Close Out continues for more than the one hundred (100) days of the date specified in the Master Schedule provided above, for reasons other than a ESTABLISHMENT Delay, ESTABLISHMENT shall have, at ESTABLISHMENT discretion, the additional right to give CFZ a written notice that it intends to deem the agreement terminated, as per Section 15.3 below.
ARTICLE 8    TRANSFER OF GOODS
8.1    Within eight weeks after Work Close Out or any termination of this contract as detailed herein, CFZ shall prepare a final statement of all transactions processed, and will transfer to ESTABLISHMENT through proper customs forms, the transactions and the possession of any equipment and works processed under this Contract, if required. Free Trade Zone beneficiary status of ESTABLISHMENT shall be ESTABLISHMENT’s responsibility.
ARTICLE 9    ESTABLISHMENT RESPONSIBILITIES
9.1    ESTABLISHMENT shall provide all requested relevant Project information to CFZ in a timely manner, including the Scope Manual and Final Layout.

-23-

9.2    ESTABLISHMENT shall provide full information regarding requirements for the Project, including a program which shall set forth ESTABLISHMENT objectives, schedule, constraints and criteria, including space requirements and relationships, flexibility, expandability, special equipment, systems, and site requirements.
9.3    All communications with the Subcontractors go through CFZ. However, if it becomes necessary for ESTABLISHMENT to communicate directly with a Subcontractor, ESTABLISHMENT shall notify CFZ in writing of the content of such communication.
9.4    ESTABLISHMENT shall promptly furnish all requested review and approval or other appropriate action with respect to all submittals by CFZ including, without limitation, any samples, estimates, schedules, budgets, shop drawings, construction Subcontracts, bid awards, Change Orders, purchase orders contracts and other items submitted and/or proposed by CFZ. Failure by ESTABLISHMENT may result in an adjustment to the Master Schedule and Contract Sum; provided, however, any such extensions or adjustments are only applicable if documented pursuant to a Change Order as provided herein.
9.5    Payment to CFZ in accordance to all Payment Schedules required for the Project subject to CFZ’s satisfaction of the Payment Application provisions set forth herein. CFZ reserves its right to cover ESTABLISHMENT unpaid invoices with the Bank Guarantee as per this Contract.
ARTICLE 10       OWNERSHIP AND USE OF DRAWINGS, SPECIFICATIONS AND OTHER DOCUMENTS
10.1    The drawings, specifications and other documents prepared by CFZ, or any Subcontractors, are instruments of the creator of such documents, through which the Work to be executed is described. CFZ may retain one record set, and shall request a second set and an AUTOCAD copy to provide to ESTABLISHMENT. CFZ should provide structural, mechanical, electrical and other necessary calculations and memoirs used to the design estimations. ESTABLISHMENT shall not own or claim a copyright in the drawings, specifications and other documents prepared by CFZ, or others, and unless otherwise indicated the corresponding creator shall be deemed the author of them and will retain all statutory and other reserved rights, in addition to the copyright. The drawings, specifications and other documents prepared by CFZ, or the contractors, and copies thereof furnished to ESTABLISHMENT, are for use solely with respect to this Project and any repairs, modifications, expansions of the Building or other uses reasonably necessary by ESTABLISHMENT to beneficially use and occupy the Building (collectively, the “Permitted Uses”). ESTABLISHMENT is granted an irrevocable, limited license to use and reproduce the drawings, specifications and other documents, appropriate to and for the performance of the Work exclusively, therefore ESTABLISHMENT may not use this documents for other projects in Costa Rica. The owner of such documents in turn, will not be allowed to use these documents for other projects in Costa Rica, unless authorized by ESTABLISHMENT for its expansion in the Park. Nonetheless, CFZ will use any information provided by ESTABLISHMENT for the development of the Project as confidential and will not own or claim a copyright over such information as used solely for the Project.

-24-

ARTICLE 11       CONTRACT SUM AND CFZ’S COMPENSATION
11.1    Contract Sum: ESTABLISHMENT intends to hire CFZ on a cost-plus basis whereby CFZ shall perform or cause to be performed the Work for the Cost of Work plus the Build-Out Construction Management Fee and Reimbursable Costs.
As Subcontracts are awarded and the value of the overall budget re-affirmed and accepted by ESTABLISHMENT, the aggregate sum of the approved Subcontract prices, all of which shall be based on a fixed price or guaranteed maximum price basis (collectively, the “Cost of Work”), together with the Build-Out Construction Management Fee and any approved Reimbursable Expenses shall be deemed the “Contract Sum”. It is understood that if and to the extent not all of the trades are bid and awarded at the same time, the Contract Sum shall be increased by Change Order to reflect the acceptance of additional bids as approved by ESTABLISHMENT.
Construction Management Fee: Compensation by ESTABLISHMENT to CFZ for performance of the Services under the Contract shall be of thirteen per cent (13%) of the Contract Sum and such percentage shall be applied to every Project invoice charged to ESTABLISHMENT, as per the Payment Application procedure and the payment schedule included within the Cash Flow.
As per Article Section 6, each Change Order shall include a Change Order Direct Cost plus its Build-Out Construction Management Fee, as well as the corresponding Payment Schedule for such Change Order.
11.2    Services to be provided by CFZ included in the Build-Out Construction Management Fee shall be all those included herein.
11.3    Significant scope variations to the Scope Manual provided to CFZ such as the addition of another phase may result in a modification (an increase or decrease, as appropriate) to the Build-Out Construction Management Fee if mutually agreed pursuant to a Change Order.
11.4    CFZ shall not perform any Additional Services, nor make any addition to or deletion from the Scope Manual except by written Change Order signed by ESTABLISHMENT Project Manager.
ARTICLE 12    
If and to the extent that the Term is extended or Build-Out Construction Management Fee is adjusted, the balance of monthly installments of the Build-Out Construction Management Fee shall be recalculated to reflect the extended Master Schedule and any adjustment in the Build-Out Construction Management Fee. Such recalculation shall result in monthly installments of the Build-Out Construction Management Fee that each are an amount equal to the unpaid balance of the Build-Out Construction Management Fee divided by the total number of months remaining in the Term for which an invoice has not been properly submitted by CFZ. Partial months shall be treated as full months for purposes of recalculating the monthly installments of the Build-Out Construction Management Fee. REIMBURSABLE COSTS

-25-

12.1    Pursuant to Article 11 herein, the Build-Out Construction Management Fee payable to CFZ shall comprise the entirety of the CFZ’s compensation for the Services. Notwithstanding the foregoing, if CFZ is required to perform services not identified or reasonably contemplated within the scope of Services identified in this Contract and such additional services require CFZ to incur additional costs associated with the Project, CFZ shall request to ESTABLISHMENT in writing, approval to incur into a reimbursable cost “Reimbursable Cost Request”, and shall include in the request the calculation of the expense in reasonable detail. If CFZ does not receive a written objection from ESTABLISHMENT regarding the Reimbursement Cost Request within three (3) days from ESTABLISHMENT receipt of the Reimbursement Cost Request, CFZ shall be authorized to deem the costs included in the Reimbursable Cost Request as an Authorized Reimbursable Cost. Utilities required to perform the Works within the premises, such as water, electricity, and similar, shall be considered an authorized Reimbursable Cost and shall be paid by ESTABLISHMENT accordingly.
12.2    Authorized Reimbursable Costs shall be paid to CFZ in the following month in which CFZ incurs into such Authorized Reimbursable Costs and shall be included in the monthly Payment Applications.
12.3    Reimbursable Costs agreed upon pursuant to Article 12.1 hereof are in addition to compensation for Services and Additional Services and include expenses incurred by CFZ and its employees and consultants in direct interest of the Project.
12.4    Permits are deemed Reimbursable Costs, and are deemed approved. CFZ will apply for such permits in accordance with the Free Trade Zone benefits when applicable; if such benefits are not applied due to causes attributable to CFZ, the amounts to be paid shall not be considered Reimbursable Costs.
ARTICLE 13       PAYMENTS TO CFZ
13.1    All payment of the Contract Sum shall be paid in accordance with a Payment Application as per Articles 5.4.3. and 5.4.4 above,
13.2    CFZ shall also include a monthly invoice including the Build-Out Construction Management Fee then due, as well as the total Authorized Reimbursable Costs incurred during such term, with attached supporting documentation.
13.3    Any payments pending and amounts due to CFZ shall be made by ESTABLISHMENT to CFZ within ten (10) calendar days after the date of receipt of the invoice approved by ESTABLISHMENT in accordance with the Payment Applications provisions set forth in Section 5.4. Any delay beyond the aforementioned thirty (30) day period shall generate interest at an annual interest of 8.5% percentage points (calculated in a year of twelve months, and each month of 30 days), and a breach is deemed to have occurred by ESTABLISHMENT. Prompt payment is absolutely necessary.

-26-

13.4    ESTABLISHMENT will hold five Percent (5%) retainage on all payments associated with the Contract Sum (“Retention”) and will hold such Retention until the Hand Over Date, unless ZFC has delivered a letter of credit issued by a bank of the Costa Rican National Banking System on behalf of ZFC, naming ESTABLISHMENT as beneficiary. Within five (5) calendar days after the Hand Over Date, CFZ shall carry out the final billing for the entire project by issuing the final invoice, deducting any advance payments as well as partial invoiced amounts, for which it will attach a note. Retainage will not be applied to any Reimbursable costs as per this contract.
ARTICLE 14    INDEMNIFICATION
In accordance with article 1045 of the Civil Code, each Party (the “Breaching Party”) agrees to indemnify and hold harmless the other Party from any loss (including reasonable attorneys fees and other out of pocket costs), damage or liability attributable to or derived from a breach of this Agreement by the Breaching Party, provided, however, that claims covered by Article 7.7 or Article 12 of this Agreement shall be resolved solely in accordance with the provisions and limitations contained in those articles, and provided further that neither Party shall be responsible to the other for any consequential damages or lost or anticipated profits, even if an authorized representative of such party is advised of the possibility or likelihood of same.
CFZ, to the fullest extent permitted by law, shall indemnify, hold harmless and defend ESTABLISHMENT, its officers, directors, employees and agents from and against claims, losses, damages, liabilities, including attorney’s fees and expenses, for bodily injury, sickness or death and property damage or destruction (other than to the Work itself) to the extent resulting from the negligent acts or omissions of CFZ, Sub Consultants, Subcontractors, or anyone employed directly or indirectly by any of them or anyone for whose acts any of them may be liable.
If an employee of CFZ, Design Consultants, Subcontractors, anyone employed directly or indirectly by any of them or anyone for whose acts any of them may be liable has a claim against ESTABLISHMENT, its officers, directors, employees or agents, CFZ’s indemnity obligation shall not be limited by any limitation on the amount of damages, compensation or benefits payable by or for CFZ, Sub Consultants, Subcontractors or other entity under any employee benefit including worker’s compensation or disability.
In no event shall either party be responsible to the other for consequential damages or loss of profit.
ESTABLISHMENT, to the fullest extent permitted by law, shall indemnify, hold harmless and defend CFZ and any of CFZ’s officers, directors, employees or agents from and against claims, losses, damages, liabilities including attorney’s fees and expenses, for bodily injury, sickness or death and property damage or destruction (other than to the Work itself) to the extent resulting from the negligent acts or omissions of ESTABLISHMENT its officers, directors, employees or agents.
ARTICLE 15       TERM AND TERMINATION

-27-

15.1    This Contract shall become effective upon the date of signature by both Parties and first payment required by ESTABLISHMENT to CFZ is fully credited under CFZ bank account (hereinafter the “Effective Date”), however the Build-Out Design and Construction term within the Master Schedule will only begin upon ESTABLISHMENT written notice to CFZ that all precedent conditions have been completed, including but not limited to approval of government and municipal permits, Initial Estimate Budget, the Scope Manual and the Construction Layout. Contract Term is estimated at 11 months (from the execution of this Agreement until Substantial Completion) based on the preliminary master schedule; once parties define the final master schedule the substantial completion date shall be adjusted accordingly within the final master schedule. Any delay on behalf of ESTABLISHMENT regarding master schedule milestones, shall be considered an ESTABLISHMENT delay and CFZ shall be entitled to delay the project on the same amount of days as the ESTABLISHMENT delay.
15.2    Either Party shall have the right to terminate this Contract with immediate effect in the event of a Substantial Breach, as hereinafter defined, of this Contract by the other Party.
15.3    A “Substantial Breach” by CFZ entitling ESTABLISHMENT to terminate with immediate effect shall be deemed to have occurred if:
		
	(a)
	bankruptcy or similar proceedings are instigated (voluntarily or involuntarily) against CFZ’s assets or CFZ;

		
	(b)
	if failure to deliver the Work, due to CFZ’s fault, exceeds one hundred (100) days of delay pursuant to Article 7.7;

		
	(c)
	CFZ interrupts its work without a legal cause or as otherwise permitted under this Contract, and does not resume within fifteen (15) days after written demand by ESTABLISHMENT ; or

		
	(d)
	Any other material breach of this Contract by CFZ which is not cured by    \  
CFZ within thirty (30) days after CFZ received of written notice by of the existence of the material breach ESTABLISHMENT .

Upon such termination, ESTABLISHMENT may take possession of the site and complete the Work utilizing any reasonable means. In this event, ESTABLISHMENT shall be obligated to pay CFZ for all Services and Work properly performed or committed (including all reimbursable and additional costs) through the date of termination. CFZ shall assign to ESTABLISHMENT, its rights under any or all subcontracts for the Work and/or all rights it may have against all Subcontractors related to warranties and guaranties provided on the Work.
Parties accept and acknowledge that ESTABLISHMENT will not terminate this agreement, and will hold CFZ harmless, will not file a claim or lawsuit against it, or request a sum for damages or losses, if the default is caused or due to Acts of God and/or Force Majeure. Also that any non 

-28-

compliance or delay, due to lack of or delay in obtaining permits that are CFZ’s responsibility, and that were diligently filed and proactively processed, shall not be considered as a Substantial Breach.
15.4    A “Substantial Breach” by ESTABLISHMENT which entitles CFZ to terminate with immediate effect shall be deemed to have occurred if:
		
	(a)
	If ESTABLISHMENT has delayed payment in accordance to approved Payment Applications for a thirty day term; or

		
	(b)
	If ESTABLISHMENT unilaterally ordered work stoppage that has carried on for sixty (60) days, or more, however all payments required have been fulfilled.

		
	(c)
	If ESTABLISHMENT materially breaches this Contract, and such breach is not cured by ESTABLISHMENT within thirty (30) days after ESTABLISHMENT received written notice by CFZ of the existence of the material breach.

Parties accept and acknowledge that CFZ will not terminate this agreement, and will hold ESTABLISHMENT harmless, will not file a claim or lawsuit against it, or request a sum for damages or losses, if the default is caused or due to Acts of God and/or Force Majeure.
15.5    Upon termination by CFZ in accordance with Article15.4, ESTABLISHMENT shall be obligated to pay CFZ:
		
	(a)
	The 25% of Build-Out Construction Management Fee that CFZ would have been entitled to if the Construction Management Agreement had been completed.

		
	(b)
	All costs of Work performed by Subcontractors plus and reasonable termination costs under such Subcontracts;

		
	(c)
	All reasonable demobilization costs; and

		
	(d)
	Fair compensation for any materials, equipment, or other property retained by ESTABLISHMENT.

15.6    As a condition of receiving the payments described in the this section, CFZ shall cooperate with ESTABLISHMENT by taking all steps necessary to accomplish the legal assignment of CFZ’s rights and benefits to ESTABLISHMENT, including the execution and delivery of reasonably required documents.
15.7    Any notice for termination must be in writing, and delivered to the other Party. Such notice must be preceded by written indication of shortcomings and provisions of adequate deadlines (and in no event less than five (5) business days) for correcting the same.
15.8    Within fifteen (15) calendar days after termination of this Contract, CFZ shall deliver to ESTABLISHMENT all relevant materials, supplies and equipment paid for by 

-29-

ESTABLISHMENT and the Contract Documents in accordance with other provisions of this Contract.
15.9    The remedies provided in this Section 15 are all remedies applicable to the Contract, and neither Party shall be responsible to the other for any consequential damages or lost or anticipated profits, arising out of or relating to this Contract, even if an authorized representative of such party is advised of the possibility or likelihood of same, and Parties warrant and acknowledge that they will not file any lawsuits or claims to recover additional amounts from the defaulting Party other than as set forth herein.
15.10    ESTABLISHMENT Guarantee. ESTABLISHMENT shall, at the time of the execution of the CMA Agreement deliver to CFZ a Performance Bond equivalent to the amount of Seven Hundred and Fifty Thousand dollars (US$750.000,00) valid until April 30th 2016. The amount of the performance bond shall be revised at least every two months in order to adjust it to the remaining amount of CFZ unpaid fees, all Performance Bonds shall be renewed at least fifteen days prior to the expiration date of the current Performance Bond . All Performance Bonds shall be emitted by a bank legally established in Costa Rica and such performance bond shall be approved by CFZ. ESTABLISHMENT Guarantee shall secure ESTABLISHMENT’s obligations and payment of any amounts due from ESTABLISHMENT to CFZ under this Contract from the time of execution and until three months after the Final Completion of this Contract. In case the Initial Estimated Budget or the final budget exceeds in more than 20% (twenty percent) the amount of the Contract Price such confirmation shall be adjusted accordingly.
15.11    
15.12    Parties agree that if ESTABLISHMENT fails to make any payment to ZFC, ZFC will be entitled to execute the Performance Bond at its sole discretion.
ARTICLE 16       WARRANTY
16.1    CFZ warrants that it will perform the Work in accordance with the highest standard of care normally practiced by firms that possess (i) expertise and experience in performing services of a similar nature at the time and place the Services are performed, and (ii) extensive familiarity with the site upon which the Project is located and surrounding areas, and with the conditions under which the Work is to be performed (the “Standard of Care”). Without limiting the foregoing, CFZ is responsible for any defect in construction or the Work for a period of five years following Final Completion, whether performed by CFZ or any subcontractor of any tier. The foregoing warranty is and shall be separate and independent from any separate manufacturer’s warranty with respect to any materials or equipment. The obligations contained in this Article 16 are CFZ’s sole warranty obligations with respect to the performance of the Work. CFZ makes no warranties relating to schedules or completion dates, budgets, the cost of the Work or the Project, the Work performed by the Subcontractors, or any other warranties, express or implied, which are not expressly set forth herein. CFZ shall have no liability for any defects in CFZ’s Services directly attributable to CFZ’s good faith use and reliance upon any Build-Out Construction Documents furnished by ESTABLISHMENT, where such Build-Out Construction Documents provided by 

-30-

ESTABLISHMENT were the direct cause of such defects, or such other information furnished by or on behalf of ESTABLISHMENT, where such other information furnished by ESTABLISHMENT was the direct cause of such defects.
16.2    Each design professional or Subcontractor is responsible for any defect in construction or the Work for a period of five years following Final Completion of the Project. The foregoing warranty is and shall be separate and independent from any separate manufacturer’s warranty with respect to any materials or equipment. CFZ and each applicable subcontractor shall take all steps necessary to ensure that the Work is performed in a manner that does not violate any such manufacturer’s warranty. CFZ will cooperate with ESTABLISHMENT in any actions taken to claim such statutory warranty. Liability shall not be applicable for the defects or damages caused by ESTABLISHMENT or due to ESTABLISHMENT fault.
16.3    The warranty does not apply to defects caused by normal wear and tear or the improper use of the finished Work in a manner for which it was not reasonably designed, intentional damage or Force Majeure.
ARTICLE 17       INSURANCE
Insurance policies, coverage and conditions will be subscribed and maintained by CFZ and ESTABLISHMENT in accordance with Schedule Nine, and proof of the validity of those insurances can be requested at any time.
ARTICLE 18    MISCELLANEOUS
18.1    Any notice or written documents shall be delivered in person, with delivery acknowledged in writing, or by recognized international courier, with evidence of delivery provided and such delivery constituting the date of notice.
		
	(a)
	To CFZ:    At Administrative Building Coyol Free Zone, Fax Number: (506) 2435-6060, to the attention of Mr. Carlos Wong, with a copy to Federico Castro ________________.

		
	(k)
	To ESTABLISHMENT    Name:  B15 Coyol Free Zone

Fax: (506) 2434-2400
Email: ________________
18.2    Any modifications to this Contract must be in writing and must be signed by both Parties.
18.3    The Parties recognize that differences sometimes arise in the course of a relationship and wish to avoid litigation. Accordingly, all claims, disputes and other matters in question between CFZ and ESTABLISHMENT arising out of or relating to this Agreement or the breach thereof, the Project, or the Work (“disputes”) shall first be submitted to negotiation and may, failing resolution, then be subject to arbitration as set forth below; however, in all other cases, all legal and equitable rights and remedies provided at law and equity are reserved. Disputes claimed by either party must 

-31-

be made by written notice. Pending final resolution of any dispute, including arbitration in accordance with this Section, CFZ shall proceed diligently with performance of the Work to the extent it is unrelated to the dispute and the subject matter of the dispute does not inhibit the progress of the Work generally, and ESTABLISHMENT shall continue to make payments to CFZ in accordance with this Agreement to the extent unrelated to the dispute. To the extent necessary in light of the circumstances, the Contract Term shall be extended by the period of time necessary to resolve any dispute. Such performance by CFZ and payment by ESTABLISHMENT shall not operate to waive or stop either party from pursuing the claim which gave rise to the dispute. If any dispute arises, ESTABLISHMENT and CFZ shall each appoint an executive officer to meet for the purpose of resolving it. If the parties’ executive officers are able to reach an agreement, the dispute will be deemed resolved.
18.4    If after fifteen (15) days from the date the dispute arose these negotiations prove unsuccessful in whole or in part , any and all disputes, claims, differences, disputes or controversies arising out of or in relation to any aspect of this Agreement, its business matter, performance, liquidation, interpretation, validity or any breach thereof, shall be resolved by arbitration in accordance with the bylaws of the International Center for Conciliation and Arbitration of the Costa Rican-American Chamber of Commerce (“CICA”). The parties hereby agree to submit voluntarily and unconditionally to its rules and bylaws and claim knowledge thereof. Disputes shall be resolved by an Arbitration Tribunal composed of three arbitrators; each party shall appoint one arbitrator, and these two arbitrators shall appoint a third arbitrator who will act as president of the Arbitration Tribunal. The Parties hereby agree, that they cannot assign their rights and obligations under this Contract totally or partially without mutual approval however ESTABLISHMENT may assign its rights and delegate its duties hereunder to any entity which is controlled by or under the common control of ESTABLISHMENT, its ultimate parent or any of its affiliates and CFZ may assign its right to compensation under this agreement, for financing purposes. The Guarantee shall survive any such assignment, and remain valid.
18.5    This Contract represents the entire arrangement between the parties concerning the subject matter hereof, and supersedes all written or oral concurrent or prior agreements or understandings with respect thereto. Neither party may claim any amendment, modification or release from any provision hereof by mutual agreement, acknowledgment or acceptance of a purchase order form or otherwise, unless made in writing and signed by authorized representative of both parties. Any conflict between the terms and conditions noted on the Contractor’s proposal and this Contract shall be governed by this Contract.
18.6    In the event that any provision of this Contract is found to be unenforceable under law, the remaining provisions shall continue in full force and effect.
18.7    This Contract shall be governed and the rights and duties created hereunder shall be interpreted and enforced according to the laws of the Republic of Costa Rica, regardless of the domicile of the Parties or the location of the Project.
18.8    This Contract has been made in 2 original copies in English language of which each of the Parties shall receive 1 copy each.

-32-

18.9    The Schedules identified in this Contract are incorporated herein by reference and are an integral part thereof.
18.10    Due to the nature of this Contract, the value for fiscal purposes cannot be estimated.
18.11    Either Party can appear before a Notary Public to file with the original copies kept by a Notary, without the presence of the other Party, at its own cost.
18.12    Confidentiality: Each of CFZ and ESTABLISHMENT shall keep in confidence all drawings, records, data, books, reports, documents and information, whether technical, commercial or financial in nature, supplied to it by or on behalf of the other party relating to the Project and the Works and shall not disclose the same in any manner otherwise than for the purpose of seeking financial assistance for the Works or for the purpose of performing its obligations hereunder, or as it may necessarily be required to disclose pursuant to the laws or orders of appropriate regulatory authorities or pursuant to any financing to the Project or any other agreement by which it may be bound; provided that nothing in this clause shall limit the parties’ right to use such documents and information in circumstances where the Contract has been terminated.
IN WITNESS WHEREOF, the parties hereto have caused this Contract to be signed by their duly authorized agent(s) the day and year first above written.

	
			
	/s/ Juan Jose Chacón

	Name: Juan Jose Chacón

	Date and Place: 
	San Jose, February 11, 2016

	By: Establishment Labs S.A.

	Tenant
	 
	 

	
					
	/s/ Álvaro Carballo Pinto
	 
	/s/ André Garnier Kruse

	Álvaro Carballo Pinto 
	 
	André Garnier Kruse

	Date and Place: 
	 
	 
	Date and Place: 
	 

	By/Zona Franca Coyol, S.A.

-33-

Schedules
Schedule One
Notarial Statements
a) ESTABLISHMENT
b) CFZ
Schedule Two
Location Plan
Schedule Three
Bill of Exchange Guarantee
Schedule Four
Preliminary Master Schedule
Schedule Five
Change Notice
Schedule Six
Form of Change Order
Schedule Seven
Subcontractor’s Termination Form
Schedule Eight
Scope Manual
Schedule Nine
Insurance Description
Schedule Ten
Preliminary Budget
Schedule Eleven
Budget Cash Flow

Schedule One
Certifications of Legal Representation

NUMERO VEINTIUNO - DOS MIL DIECISEIS. FEDERICO CASTRO KAHLE, NOTARIO PUBLICO DE SAN JOSE CON OFICINA EN ESCAZU, EDIFICIO TERRAFORTE, CUARTO P1SO, BUFETE LEX COUNSEL, CERTIFICA: A solicitud de ZONA FRANCA COYOL, S.A., con cedula de persona jurídica número tres- ciento uno- cuatrocientos veinte mil quinientos doce, que de conformidad con -el Sistema Digitalizado del Registro de Personas Jurídicas del Registro Público, bajo to cedula de persona jurídica número tres- ciento uno- cuatrocientos veinte mil quinientos doce y bajo el tomo quinientos sesenta y cinco, asiento once mil quinientos noventa y dos, consecutivo uno, secuencia cuatro, que: a) ZONA. FRANCA COYOL, S.A., se encuentra debidamente constituida, inscrita y vigente; b) los Señores ALVARO EDUARDO CARBALLO PINTO, mayor, casado, empresario, vecino de San José, con cedula de identidad número uno- quinientos treinta y seis- seiscientos cincuenta y cinco, HUBER ANDRE GAMIER KRUSE, mayor, casado, empresario, vecino Alajuela, con cedula de identidad número uno- cuatrocientos dieciséis- mil trescientos cuarenta y cuatro y JORGE MONGE AGUERO, mayor, casado, empresario, vecino de San José, con cedula de identidad número uno- cuatrocientos trece-mil trescientos cuarenta y uno, son respectivamente PRESIDENTE, SECRETARIO y TESORERO de la Junta Directiva dc la sociedad, a quienes les corresponde la representación judicial y extrajudicial de la sociedad con facultades de apoderado generalísimo sin límite de suma de conformidad con el articulo mil doscientos cincuenta y tres del Código Civil, debiendo actuar conjuntamente al menos dos de ellos. Podrán, actuando de la forma dicha, nombrar apoderados con la designación y atribuciones quo harán constar en el propio acto del nombramiento, sin por ello perder sus facultades originales. c) El señor CARLOS JONFAI WONG ZUÑIGA, mayor, casado dos veces, economista, vecino de San José, con cedula de identidad número uno- seiscientos sesenta y cuatro- novecientos ochenta y nueve, es GERENTE GENERAL de la sociedad con facultades de Apoderado Generalísimo limitado a la suma de cien mil dólares, moneda de curso legal de los Estados Unidos de América o su equivalente en colones de Costa Rica, de conformidad con el articulo mil doscientos cincuenta y tres del Código Civil. Sin embargo, para vender, enajenar, gravar o en cualquier otra forma disponer de los activos, las inversiones o los bienes inmuebles de la sociedad, deberá contar con la aprobación previa y expresa de la junta directiva o de la asamblea de accionistas. El apoderado podrá, respetando las limitaciones que sobre el recaen, y siempre dentro de las facultades otorgadas en este poder, nombrar apoderados con la designación y atribuciones que hará constar en el propio acto de nombramiento, pudiendo revocar este y hacer nuevos nombramientos, 

cuantas veces juzgue necesario, sin por ello perder sus facultades originales. Sin embargo, en las sustituciones u otorgamientos de poderes que efectué, el apoderado no podrá otorgar poderes mayores a los que ostenta, salvo que cuente con la autorización de la junta directiva o asamblea de accionistas.- Expido la presente certificación en lo conducente, no hay asientos posteriores que modifiquen, alteren, condicionen o restrinjan, ni desvirtué lo aquí certificado, al tenor del articulo ciento diez del Código Notarial.- ES CONFORME. Se agregan y cancelan las especies fiscales de ley. Se expide en San José, a las diez horas veinte minutos del dos de febrero del año dos mil dieciséis.

REPUBLICA DE COSTA RICA 
REGISTRO NACIONAL 
CERTIFICACION LITERAL 
NUMERO DE CERTIFICACION: RNPDIGITAL-4930122-2016 
PERSONA JURIDICA: 3-101-366337
	
	
	 

DATOS GENERALES
RAZON SOCIAL O DENOMINACION: ESTABLISHMENT LABS SOCIEDAD ANONIMA
ESTADO ACTUAL: INSCRITA
DOCUMENTO ORIGEN: TOMO: 531 ASIENTO: 38 FECHA INSCRIPCION / TRASLADO: 31/03/2004
DOMICILIO: ALAJUELA-ALAJUELA LA GARITA, ZONA FRANCA COYOL, EDIFICIO B QUINCE, OFICINAS DE ESTABLISHMENT LABS.
OBJETO/FINES (SINTESIS): COMERCIO, EXPORTACION, IMPORTACION, GANADERIA, VENDER, HIPOTECAR, DISPONER DE BIENES, LOS BIENES RAICES, FIDEICOMISOS, RENDIR TODA CLASE DE FIANZAS Y GARANTIAS, RECIBIR DONACIONES, LEGADOS
PLAZO DE LA ENTIDAD JURIDICA: INICIO: 18/01/2004 VENCIMIENTO: 18/01/2104
PRORROGAS EN EL PLAZO DE LA ENTIDAD JURIDICA: NO INDICA
NUMERO LEGALIZACION: 4061010315591
FECHA LEGALIZACION: 04/07/2014
CONFORMACION DEL CAPITAL O PATRIMONIO
FECHA DE INSCRIPCION: 25/04/2014 TIPO DE CAPITAL: SUSCRITO Y PAGADO TIPO DE MONEDA: DOLARES
CLASE DE ACCION O TITULO: ACCIONES COMUNES Y NOMINATIVAS
CANTIDAD TITULOS: 1 MONTO: 10,268,857 00 TOTAL: 10,268,857.00
NO EXISTEN MAS REGISTROS DE CAPITAL/PATRIMONIO PARA LA PERSONA JURIDICA
ADMINISTRACION
PLAZO DE DIRECTORES Y/O PRORROGAS: LA JUNTA DIRECTIVA, EL GERENTE GENERAL Y EL FISCAL SON NOMBRADOS POR TRES ANOS
LA JUNTA DIRECTIVA NO TIENE FACULTAD PARA OTORGAR PODERES
REPRESENTACION
LA REPRESENTACION JUDICIAL Y EXTRAJUDICIAL DE LA SOCIEDAD CON FACULTADES DE APODERADO GENERALISIMO SIN LIMITE DE SUMA PARA TODOS LOS NEGOCIOS DE LA SOCIEDAD DE CONFORMIDAD CON EL ARTICULO 1253 DEL CODIGO CIVIL SERA EJERCIDA POR DOS MIEMBROS DE LA JUNTA DIRECTIVA 

SIEMPRE QUE ACTUEN EN CUALQUIER DE LAS SIGUIENTES COMBINACIONES: A) EL PRESIDENTE CONJUNTAMENTE CON EL SECRETARIO, O CON EL TESORERO, O CON EL VOCAL UNO; B) EL VICEPRESIDENTE CONJUNTAMENTE CON EL SECRETARIO, O CON EL TESORERO, O CON EL VOCAL UNO; C) EL VOCAL DOS CONJUNTAMENTE CON EL SECRETARIO, O CON EL TESORERO, O CON EL VOCAL UNO. EL PRESIDENTE, VICEPRESIDENTE, SECRETARIO Y TESORERO DE LA JUNTA DIRECTIVA, PODRAN ACTUAR INDIVIDUALMENTE CON FACULTADES DE APODERADOS LIMITADOS A LA SUMA DE QUINCE MIL DOLARES MONEDA DE CURSO LEGAL DE LOS ESTADOS UNIDOS DE AMERICA O SU EQUIVALENTE EN MONEDA NACIONAL; SIN EMBARGO, NO PODRAN REALIZAR NINGUNA DE LAS ACCIONES RESERVADAS A LA JUNTA DIRECTIVA, SIN LA AUTORIZACION DE ESTA, DE ACUERDO CON LO ESTITUPULADO EN ESTOS ESTATUTOS. ADICIONALMENTE, LA COMPANIA TENDRA UN GERENTE GENERAL QUIEN PODRA SER SOCIO O NO Y QUIEN PODRA SER A SU VEZ, ALGUNO DE LOS MIEMBROS DE LA JUNTA DIRECTIVA A EXCEPCION DEL PRESIDENTE. EL GERENTE GENERAL EJERERA ASI MISMO LA REPRESENTACION DE LA SOCIEDAD Y CON TAL FIN TENDRA PODER GENERAL LIMITADO A LA SUMA DE QUINIENTOS MIL DOLARES, MONEDA DE CURSO LEGAL DE LOS ESTADOS UNIDOS DE AMERICA, DE CONFORMIDAD CON EL ARTICULO 1255 DEL CODIGO CIVIL. ACTUANDO DE MANERA INDICADA, TAMBIEN PODRAN CONFERIR U OTORGAR PODERES DE TODA CLASE A CUALQUIER PERSONA CON LAS FACULTADES, LIMITACIONES Y PLAZOS QUE CONSIDEREN CONVENIENTES, SIN EXCEDER SUS FACULTADES. LOS PODERES DE LOS REPRESENTANTES LEGALES DE LA COMPAÑIA NUNCA PODRAN SOBREPASAR LA AUTORIDAD Y PODERES DE LA JUNTA DIRECTIVA O DE LA ASAMBLEA GENERAL DE ACCIONISTAS, COMO SE ESTABLECE EN EL PACTO SOCIAL. LOS PODERES DE LOS REPRESENTANTES LEGALES NO LOS FACULTA PARA TOMAR ACCION ALGUNA REFERENTE A ASUNTOS QUE REQUIEREAN AUTORIZACION DE LA ASAMBLEA GENERAL DE ACCIONISTAS O DE LA JUN TA DIRECTIVA.
NOMBRAMIENTOS
JUNTA DIRECTIVA
FECHA DE INSCRIPCION: 25/04/2014 CARGO: PRESIDENTE
OCUPADO POR: ROBERTO EDUARDO PONCE ROMAY PASAPORTE: 17973652 N 
REPRESENTACION: REPRESENTACION JUDICIAL Y EXTRAJUDICIAL
VIGENCIA: INICIO: 22/10/2013 VENCIMIENTO: 22/10/2016
FECHA DE INSCRIPCION: 25/04/2014 CARGO: TESORERO
OCUPADO POR: DIEGO FRANCISCO GOMEZ DUENAS CEDULA DE IDENTIDAD: 1-0822-0493
REPRESENTACION: REPRESENTACION JUDICIAL Y EXTRAJUDICIAL
VIGENCIA: INICIO: 22/10/2013 VENCIMIENTO: 22/10/2016
FECHA DE INSCRIPCION: 25/04/2014 CARGO: SECRETARIO
OCUPADO POR: JUAN JOSE CHACON QUIROS CEDULA DE IDENTIDAD: 1-0822-0006

REPRESENTACION: REPRESENTACION JUDICIAL Y EXTRAJUDICIAL
VIGENCIA: INICIO: 22/10/2013 VENCIMIENTO: 22/10/2016
FECHA DE INSCRIPCION: 25/04/2014 CARGO: VICEPRESIDENTE
OCUPADO POR: FEDERICO ANTONIO ZAMORA CAVALLINI CEDULA DE IDENTIDAD: 1-0738-0065
REPRESENTACION: REPRESENTACION JUDICIAL Y EXTRAJUDICIAL
VIGENCIA: INICIO: 22/10/2013 VENCIMIENTO: 22/10/2016
FECHA DE INSCRIPCION: 22/07/2014 CARGO: VOCAL 02
OCUPADO POR: PERCY EDUARDO GRUNDY CASTANOS PASAPORTE: 2441471
REPRESENTACION: REPRESENTACION JUDICIAL Y EXTRAJUDICIAL
VIGENCIA: INICIO: 20/06/2014 VENCIMIENTO: 22/10/2016
FECHA DE INSCRIPCION: 22/07/2014 CARGO: VOCAL 01
OCUPADO POR: OLIVIER TOURNIAIRE PASAPORTE: 10 AL 27856 
REPRESENTACION: NO APLICA
VIGENCIA: INICIO: 20/06/2014 VENCIMIENTO: 22/10/2016
NO EXISTEN MAS NOMBRAMIENTOS EN JUNTA DIRECTIVA CON REPRESENTACION NOMBRAMIENTOS U OTROS CARGOS DE LA PERSONA JURIDICA
FECHA DE INSCRIPCION: 06/10/2009 CARGO: AGENTE RESIDENTE
OCUPADO POR: LUIS MANUEL GUTIERREZ CHACON CEDULA DE IDENTIDAD: 1-0796-0788
REPRESENTACION: NO APLICA
VIGENCIA: INICIO: 25/08/2009 VENCIMIENTO: 18/01/2104
DIRECCION: SAN JOSE, PASEO COLON, EN EL OCTAVO PISO DE TORRE MERCEDES, OFICINAS DE FEINZAIG, SCHARF & VAN DER PUTTEN.
FECHA DE INSCRIPCION: 25/04/2014 CARGO: FISCAL
OCUPADO POR: GONZALO ERNESTO VELAZQUEZ MARTINEZ CEDULA DE RESIDENCIA: 1253328001243
REPRESENTACION: NO APLICA
VIGENCIA: INICIO: 22/10/2013 VENCIMIENTO: 22/10/2016
FIN DE LOS NOMBRAMIENTOS O CARGOS DE LA PERSONA JURIDICA
PODERES QUE HA OTORGADO LA PERSONA JURIDICA
INFORMACION DETALLADA O POSIBLES MOVIMIENTOS EN LA CERTIFICACION DEL PODER CORRESPONDIENTE
CITAS DE INSCRIPCION DEL PODER: 546 - 5992 - 1 - 3 FECHA: 06/04/2005 
TIPO DE PODER: PODER GENERAL ESTADO ACTUAL DEL PODER: INSCRITO

CITAS DE INSCRIPCION DEL PODER: 2009 - 226748 - 1 - 7 FECHA: 06/10/2009 
TIPO DE PODER: PODER GENERAL ESTADO ACTUAL DEL PODER: INSCRITO
CITAS DE INSCRIPCION DEL PODER: 2009 - 226748 - 1 - 8 FECHA: 06/10/2009
TIPO DE PODER: PODER GENERALISIMO ESTADO ACTUAL DEL PODER: INSCRITO
NO EXISTEN MAS PODERES OTORGADOS POR LA PERSONA JURIDICA
NO EXISTE INFORMACION DE AFECTACIONES SOBRE LA PERSONA JURIDICA
NO EXISTE INFORMACION DE MOVIMIENTOS PENDIENTES SOBRE LA PERSONA JURIDICA
	
	
	NO EXISTE INFORMACION DE OBSERVACIONES SOBRE LA PERSONA JURIDICA

ESTA CERTIFICACION, CUYOS DERECHOS ARANCELARIOS FUERON DEBIDAMENTE CANCELADOS, CONSTITUYE DOCUMENTO PUBLICO CONFORME LO ESTABLECEN LOS ARTICULOS 369 DEL CODIGO PROCESAL CIVIL, 5 INCISO D) DE LA LEY DE CERTIFICADOS, FIRMAS DIGITALES Y DOCUMENTOS ELECTRONICOS N.8454, Y EL DECRETO EJECUTIVO N. 35488-J, PUBLICADO EN LA GACETA N. 196, DEL 8 DE OCTUBRE DE 2009. EN DICHO MARCO LEGAL SE ESTABLECE LA OBLIGATORIEDAD DE RECIBIR ESTE DOCUMENTO POR PARTE DE LOS ENTES PUBLICOS Y PRIVADOS, ASI COMO PARA LOS PARTICULARES, EN CASO DE QUE SE LE PRESENTEN PROBLEMAS PARA LA RECEPCION DE ESTE DOCUMENTO Y APLICACION DE SUS EFECTOS LEGALES, SIRVASE COMUNICARLO AL CENTRO DE ASISTENCIA AL USUARIO, TELEFONO. 2202-0888.
ESTIMADO USUARIO, EL REGISTRO NACIONAL LE INDICA QUE EL VALOR DE LA PRESENTE CERTIFICACION FUE ESTABLECIDO POR LA JUNTA ADMINISTRATIVA EN LA SUMA DE DOS MIL CUATROCIENTOS OCHENTA Y DOS COLONES CON CINCUENTA CENTIMOS MAS LOS TIMBRES RESPECTIVOS; NINGUNA PERSONA FISICA 0 JURIDICA PUEDE VARIAR ESE VALOR.
EMITIDA A TRAVES DEL PORTAL DE SERVICIOS DIGITALES Y CON DATOS CONSULTADOS A UNA REPLICA OFICIAL DE LA BASE DE DATOS DEL REGISTRO NACIONAL, A LAS 11 HORAS 16 MINUTOS Y 14 SEGUNDOS, DEL 11 DE FEBRERO DE 2016.  PODRA SER VERIFICADA EN EL SITIO www.rnpdigital.com DENTRO DE LOS SIGUIENTES 15 DIAS NATURALES.

Schedule Two
Location Plan

Schedule Three
Performance Bond

Schedule Four
Preliminary Master Schedule

Schedule Five
Change Notice

Schedule Six
Form of Change Order

Schedule Seven
SubContractor Termination Form

Proyecto XXXXXXXXXX
FINIQUITO
Empresa Contratada
Los suscritos, xxxxxxxxxxxxxxx_________________, portador de la cedula de identidad numeroxxxxxxxxxxxxx, en su condición de Gerente con facultades suficientes para este acto de xxxxxxxxxxx, cedula jurídica número xxxxxxxxxxxxxxxxxxxxxxx; y Carlos Wong Zúñiga, portador de la cedula de identidad uno - seiscientos sesenta y cuatro - novecientos ochenta y nueve, en su condicion de apoderado con facultades suficientes para este acto de la sociedad denominada ZONA FRANCA COYOL S.A, cedula de persona jurídica número tres - ciento uno - cuatrocientos veinte mil quinientos doce, hemos convenido en celebrar el presente finiquito al contrato de XXXXXXXXXXXXXX Proyecto XXXXXXXX, lo cual hacemos en los siguientes términos:
PRIMERO: XXXXX en su condición de contratista participo en XXXXXXX del proyecto XXXXXXXX, desarrollado en Zona Franca Coyol, entre los días XXXXXXX. Las obras realizadas por XXXXXX se describen a continuación: XXXXXXXXXXXX.
SEGUNDO: La empresa XXXXX en su condición individual y en representación y asumiendo responsabilidad por todos sus subcontratistas, declara y garantiza que la realización de las obras descritas en el punto primero de este documento fueron entregadas dentro de los plazos efectivamente determinados y expresamente descritos en la nota de adjudicaci6n de las obras, lo cual acepta Zona Franca Coyol.
TERCERO: XXXXXX declara y garantiza que ha recibido de la empresa Zona Franca Coyol la totalidad del precio por concepto de la prestación de los servicios, gastos y costos de realización del proyecto pactados en el contrato a que se refiere la cláusula anterior. En virtud de lo anterior XXXXX declara y garantiza que se da por satisfecha enteramente en cuanto a sus pretensiones pecuniarias. En los siguientes 12 días posteriores a su presentación formal a Zona Franca Coyol S.A. se hará efectiva la devolución de retenciones a XXXXXX por un monto acumulado de $ XXXXXX. (XXXXXXX). Este documento se deberá tramitar el primer, segundo y tercer viernes del mes.
CUARTO: XXXXX declara y garantiza que ha entregado a Zona Franca Coyol copia digital de los pianos as-built de las obras realizadas y que dichos pianos son una representaci6n fiel de las características de dichas obras, tal a como fueron construidas por la empresa XXXXXXX.
QUINTO: XXXXX declara y garantiza que no se encuentra pendiente de resolución ningún conflicto o diferencia de carácter legal o económico que devenga de la relación contractual o de cualesquiera otros hechos o situaciones de carácter extra contractual con respecto a Zona Franca Coyol S.A. Igualmente, Zona Franca Coyol S.A. declara y garantiza que no se encuentra pendiente de resolución ningún conflicto o diferencia de carácter legal o económico que devenga de la relación contractual o de cualesquiera otros hechos o situaciones de carácter extra contractual con respecto a XXXXX.

SEXTO: Ambas partes declaran y garantizan que por haberse satisfecho todas sus pretensiones derivadas de la relación contractual suscrita entre las mismas enunciadas en este documento se liberan expresa, total e incondicionalmente de toda responsabilidad contractual o extra contractual, salvo por las garantías legales que debe asumir XXXXX por la obra ejecutada.
SEPTIMO: Ambas partes declaran y garantizan que todas las manifestaciones efectuadas en este documento son total, completa y absolutamente veraces y que a la fecha de firma de este documento no conocen de ningún hecho o circunstancia que pudiera afectar la veracidad de las mismas.
En fe de lo anterior firmamos en la ciudad de San José, el día XXXXXXXXXX.
	
			
	Representante
	 
	Carlos Wong Zuñiga

	Empresa
	 
	Zona Franca Coyol S.A.

Schedule Eight
Scope Manual

	
			
	
	BASIS OF DESIGN

	Codigo: FO-AP-008

	Version: 1.00

	Pagina 1 de 54

	Fecha de aprobación:

	1 de Julio de 2015

ESTABLISHMENT LABS
MANUFACTURING PLANT
BASIS OF DESIGN LEED
VERSION 2.0
OCTOBER 2015
Establishment Labs BoD.Leed V.2,0
October, 2015 - 1/54

Schedule Nine
Insurance Description

ZONA FRANCA COYOL 
INSURANCE CONDITIONS
The parties to the following document are:
ZFC: Zona Franca Coyol, S. A.
CLIENT/Tenant: Establishment Labs
The following document establishes the minimum insurance policy conditions applicable for agreements regarding properties in Zona Franca Coyol. In order for any agreement in Zona Franca Coyol to be valid, Parties must comply with the following insurance policies as applicable, unless Parties agree differently.
TYPE OF AGREEMENT: Cold Shell Building Construction Agreement (CSB Agreement)
	
		
	Responsible Party
	Type of Insurance

	ZFC
	Insured: ZFC
Name and Description: Construction All-risk policy (Todo Riesgo de Construccion), or its equivalent, to cover all construction risks that derive from the execution of the CSB Agreement. The policy will be acquired within the forty-five (45) days following the no later than at the start of works on Site for the execution date of the CSB contract. Notwithstanding the existence of this policy, CLIENT and/or subcontractor, shall be responsible for all damages or accidents caused by their actions or omissions within the construction site.
Amount: 100% of the construction cost of the facility to be built (cold shell).
Policy paid by: ZFC
Deductibles paid by: ZFC, except in events caused by willful misconduct or negligence of Client and or its subcontractors, which will be covered by Client.

	ZFC
	Insured: ZFC employees.
Name and Description: Workers Compensation (Riesgos del Trabajo), as required by Law.
Amount: As required by law.
Policy paid by: ZFC

TYPE OF AGREEMENT: Construction Management Agreement (CMA)
	
		
	Responsible Party
	Type of Insurance

	ZFC
	Insured: CLIENT
Name and description: Construction All Risk policy (Todo Riesgo de Construccion y Montaje) or its equivalent, to cover all construction risks that derive from the execution of the CMA Agreement. This insurance will provide insurance proceeds to insure repair and/or reconstruction of the improvements, up to the total cost of the CMA.
The policy will be acquired within the forty-five (45) days following the date in which ZFC obtained the scope manual, and the CLIENT approval of the preliminary budget.
Amount: 100% of the construction cost of the CMA scope as per the approved budget.
Policy paid by: CLIENT
Deductibles paid by: CLIENT except in events caused by willful misconduct or negligence of CFZ and or its subcontractors, which will be covered by CFZ or its subcontractors.
Observations: Will be provided by CLIENT. May be added to the Cold Shell Building Construction All Risk Insurance Policy.

	ZFC
	Insured: ZFC employees.
Name and Description: Workers Compensation (Riesgos del Trabajo), as required by Law.
Amount: As required by law.
Policy paid by: ZFC

	 
	 

	Responsible Party
	Type of Insurance

	ZFC
	Insured: CLIENT
Name and description: Cargo Insurance, to cover the freight and transport of equipment and machinery required under the CMA contract. Insurance shall be warehouse-warehouse.
The policy will be acquired within the forty-five (45) days following the date in which ZFC obtained the scope manual, and the CLIENT approval of the preliminary budget.
Amount: 100% of the value of the equipment, freight and transport cost plus 10%.
Policy paid by: CLIENT
Deductibles paid by: CLIENT.

	 
	 

TYPE OF AGREEMENT: Agreements with subcontractors
	
		
	Responsible Party
	Type of Insurance

	Subcontractor
	Insured: Subcontractor employees.
Name and Description: Workers Compensation (Riesgos del Trabajo), as required by Law, in accordance with the activity performed by subcontractor, and for that project
Amount: As required by law.
Policy paid by: Subcontractor

	Subcontractor
	Insured: Subcontractor
Name and Description: Construction Civil Liability of Subcontractor. To cover all risks derived from performing the works, including personal injuries and accidental death, inside or outside the construction site, that result from the work performed as per the corresponding contract.
The subcontractor shall be responsible of any risk, exclusion, limitation, outstanding amount, including corresponding deductibles and/or any other factor that reduces the scope of coverage of the insurance policies hired.
Amount: At least two hundred and fifty thousand dollars (US$250,000) per event.
Policy paid by: Subcontractor
Deductibles paid by: Subcontractor
Observations: This policy shall not be applicable for any contract with a cost of US$ 50,000 or lower. In these cases, ZFC’s policies shall respond. ZFC will be added as additional insured.

	Subcontractor
	Insured: Subcontractor and subcontractors professionals.
Name and description: Professional Civil Liability Policy. Subcontractors that develop activities that require professionals to act personally (such as design), shall keep this policy.
Amount: At least two hundred and fifty thousand (US
$250.000). The policy limit provided herein, dies not limit
subcontractors responsibility before ZFC and/or CLIENT.
Policy paid by: Subcontractor
Deductibles paid by: Subcontractor

	Subcontractor
	Insured: Subcontractor
Name and description: Commercial Individual Liability Insurance Policy ( Responsabilidad Civil por equipo movil) to insure all mobile machinery, equipment, vehicles, tools, etc. used to perform the works.
Amount: At least one hundred thousand (US $100,000.00). The policy limit provided herein, does not limit subcontractors responsibility before ZFC and/or CLIENT. In no event shall ZFC or CLIENT be responsible before any subcontractor for acts and/or consequences, generated by other subcontractors or by third parties.
Policy paid by: Subcontractor
Deductibles paid by: Subcontractor

TYPE OF AGREEMENT: Lease Agreement
	
		
	 
	Type of Insurance

	ZFC
	Insured: ZFC
Name and Description: AllRisk insurance that includes the coverage against earthquake, fire, and any other damage resulting from nature to protect the building up to a cold shell. ZFC is not responsible for improvements or equipment, or any other object or person within the building.
Amount: Replacement value up to a cold shell.
Policy paid by: ZFC
Deductibles paid by: The party that caused the insured event. ZFC’s policy shall only be applicable if the insured event was caused by an act or omission of ZFC, or acts of God. If for any reason, ZFC’s policy has to be used for actions generated by a third party. Such third party shall cover the deductibles, as well
as any sanction to ZFC for the use of the policy, such as increment in policy fees.

	ZFC
	Insured: ZFC
Name and Description: Commercial General Liability Program. ZFC is not responsible for improvements or equipment, or any other object or person within the building.
Amount: Two million dollars (US$2,000,000.00)
Policy paid by: ZFC
Deductibles paid by: The party that caused the insured event. ZFC’s policy shall only be applicable if the insured event was caused by an act of ZFC defined under the policy. If for any reason, ZFC’s policy has to be used for actions generated by a third party. Such third party shall cover the deductibles, as well
as any sanction to ZFC for the use of the policy, such as increment in policy fees

	CLIENT
	Insured: CLIENT
Name and Description: Commercial General Liability Program. ZFC is not responsible for improvements or equipment, or any other object or person within the building.
Amount: Two million dollars (US$2,000,000.00)
Policy paid by: CLIENT
Deductibles paid by: The party that caused the insured event. CLIENT’s policy shall only be applicable if the insured event was caused by an act of CLIENT defined under the policy. If for any reason, CLIENT’s policy has to be used for actions generated by a third party. Such third party shall cover the deductibles, as well as any sanction to CLIENT for the use of the policy, such as increment in policy fees

	CLIENT
	Insured: CLIENT
Name and Description: All Risk insurance to protect the goods of his/her property inside the property.
Amount: Replacement Value
Policy paid by: CLIENT
Deductibles paid by: CLIENT.

Important: ZFC does not insure business losses. In no event, including any of the agreements provided in this document, shall ZFC it be liable for consequential damages or loss of profits.

Schedule Ten
Preliminary Budget

Establishment Labs: Building Improvements
Order of Magnitude Estimation and Reference Cash Flow
	
									
	ORDER OF MAGNITUDE ESTIMATION

	DESCRIPTION
	QUANTITY
	UNIT
	COST/m2
	TOTAL COST

	TOTAL BUDGET ESTIMATION
	2580
	m2
	

	$2,239.41
	

	

	$5,777,690.00
	

	Design/Inspection + Construction Management
	13
	%
	

	$5,113,000.00
	

	

	$664,690.00
	

	Soft Costs
	2580
	m2
	

	$43.80
	

	

	$113,000.00
	

	Construction Risk Insurance
	1
	glo
	

	$18,000.00
	

	

	$18,000.00
	

	Permits
	1
	glo
	

	$15,000.00
	

	

	$15,000.00
	

	Campsite
	1
	glo
	

	$10,000.00
	

	

	$10,000.00
	

	Surveyor control
	1
	glo
	

	$2,000.00
	

	

	$2,000.00
	

	Potable water consumption
	1
	glo
	

	$3,000.00
	

	

	$3,000.00
	

	Power consumption
	1
	glo
	

	$7,000.00
	

	

	$7,000.00
	

	Legal advisory
	1
	glo
	

	$2,000.00
	

	

	$2,000.00
	

	Quality control
	1
	glo
	

	$15,000.00
	

	

	$15,000.00
	

	Environmental regency
	1
	glo
	

	$3,000.00
	

	

	$3,000.00
	

	Site security
	1
	glo
	

	$25,000.00
	

	

	$25,000.00
	

	Cleaning crew
	1
	glo
	

	$5,000.00
	

	

	$5,000.00
	

	Temporary lighting
	1
	glo
	

	$8,000.00
	

	

	$8,000.00
	

	Direct Costs
	2600
	m2
	

	$1,923.08
	

	

	$5,000,000.00
	

Schedule Eleven
Budget Cash Flow

Establishment Labs: Building Improvements
Cash Flow
	
																																				
	ORDER OF MAGNITUDE ESTIMATION
	 
	ESTIMATED CASH FLOW

	DESCRIPTION
	QUANTITY
	UNIT
	COST/m2
	TOTAL COST
	SEP
	FEB
	MAR
	APR
	MAY
	JUN
	JUL
	AUG
	SEP

	TOTAL BUDGET ESTIMATION
	2580
	m2
	

	$2,239.41
	

	

	$5,777,690.00
	

	

	$50,000.00
	

	

	$248,600.00
	

	

	$75,710.00
	

	

	$50,850.00
	

	

	$248,035.00
	

	

	$1,499,623.00
	

	

	$1,954,281.00
	

	

	$1,130,791.00
	

	

	$519,800.00
	

	Design/Inspection + Construction Management
	13
	%
	

	$5,113,000.00
	

	

	$664,690.00
	

	

	$50,000.00
	

	

	$28,600.00
	

	

	$8,710.00
	

	

	$5,850.00
	

	

	$28,535.00
	

	

	$172,523.00
	

	

	$180,581.00
	

	

	$130,091.00
	

	

	$59,800.00
	

	Soft Costs
	2580
	m2
	

	$43.80
	

	

	$113,000.00
	

	

	$—
	

	

	$30,000.00
	

	

	$22,000.00
	

	

	$15,000.00
	

	

	$14,500.00
	

	

	$12,100.00
	

	

	$8,700.00
	

	

	$10,700.00
	

	

	$—
	

	Construction Risk Insurance
	1
	glo
	

	$18,000.00
	

	

	$18,000.00
	

	 
	 
	 
	 
	 
	 
	 
	 
	 

	Permits
	1
	glo
	

	$15,000.00
	

	

	$15,000.00
	

	 
	 
	 
	 
	 
	 
	 
	 
	 

	Campsite
	1
	glo
	

	$10,000.00
	

	

	$10,000.00
	

	 
	 
	 
	 
	 
	 
	 
	 
	 

	Surveyor control
	1
	glo
	

	$2,000.00
	

	

	$2,000.00
	

	 
	 
	 
	 
	 
	 
	 
	 
	 

	Potable water consumption
	1
	glo
	

	$3,000.00
	

	

	$3,000.00
	

	 
	 
	 
	 
	 
	 
	 
	 
	 

	Power consumption
	1
	glo
	

	$7,000.00
	

	

	$7,000.00
	

	 
	 
	 
	 
	 
	 
	 
	 
	 

	Legal advisory
	1
	glo
	

	$2,000.00
	

	

	$2,000.00
	

	 
	 
	 
	 
	 
	 
	 
	 
	 

	Quality control
	1
	glo
	

	$15,000.00
	

	

	$15,000.00
	

	 
	 
	 
	 
	 
	 
	 
	 
	 

	Environmental regency
	1
	glo
	

	$3,000.00
	

	

	$3,000.00
	

	 
	 
	 
	 
	 
	 
	 
	 
	 

	Site security
	1
	glo
	

	$25,000.00
	

	

	$25,000.00
	

	 
	 
	 
	 
	 
	 
	 
	 
	 

	Cleaning crew
	1
	glo
	

	$5,000.00
	

	

	$5,000.00
	

	 
	 
	 
	 
	 
	 
	 
	 
	 

	Temporary lighting
	1
	glo
	

	$8,000.00
	

	

	$8,000.00
	

	 
	 
	 
	 
	 
	 
	 
	 
	 

	Direct Costs
	2600
	m2
	

	$1,923.08
	

	

	$5,000,000.00
	

	

	$—
	

	

	$190,000.00
	

	

	$45,000.00
	

	

	$30,000.00
	

	

	$205,000.00
	

	

	$1,315,000.00
	

	

	$1,765,000.00
	

	

	$990,000.00
	

	

	$460,000.00Exhibit

Exhibit 10.15

LEASE AGREEMENT
Entered into at the city of San José, on the 7th day of the month of August of the year 2015, the "Effective Date" between:
ZONA FRANCA COYOL, S. A., corporate identification card number three- one hundred one-four hundred and twenty thousand five hundred twelve, (the "Landlord"), registered in the Mercantile Section of the Public Registry under book five hundred sixty, entry ten thousand three hundred and seventy nine, consecutive one, hereon represented by Álvaro Carballo Pinto, personal identity card number one - five hundred and thirty six - six hundred and fifty five, and Huber André Garnier Kruse, personal identity card number one- four hundred sixteen- one thousand three hundred forty four, and, acting jointly and with sufficient authority for the execution of this lease agreement which legal representation is duly recorded in the Mercantile Section of the Public Registry under book five hundred and sixty five, entry eleven thousand five hundred and ninety two, consecutive one, as certified in Exhibit One. 
for the one part and for the other,
Establishments Labs, S.A., corporate identification card number three- one hundred one- three hundred and sixty nine thousand three hundred and thirty seven (the "Tenant"), registered in the Mercantile Section of the Public Registry under book five hundred seventy four, entry sixty six thousand three hundred and seventy nine, consecutive one, hereon represented by Juan José Chacón, with personal identity card number one – eight hundred twenty two- cero cero six, with sufficient authority for the execution of this lease agreement which legal representation is duly recorded in the Mercantile Section of the Public Registry under book two thousand and nine, entry two hundred twenty six thousand seven hundred and forty eight, consecutive one, as certified in Exhibit One.
Whereas
1.    Landlord is the registered owner of a property (the "Property"), located in the "Condominio Horizontal Industrial Comercial con Fincas Filiales Primarias Individualizadas (FFPI) Zona Franca Coyol" (the "Condominium" or "Zona Franca Coyol"), condominium identity number 3‐109- 533883, a condominium registered in the Costa Rican Public Registry, Province of Alajuela, Property Number M‐2640- 000, filial lot number twenty six (26), hereinafter the "Property", registered in the Public Registry Property of Alajuela, Property Number 68517- F- 000.
2.    The Condominio Horizontal Industrial Comercial con Fincas Filiales Primarias Individualizadas (FFPI) Zona Franca Coyol, "Zona Franca Coyol", is a Free Trade Zone.  The Condominium and Park Administrator is the Landlord, or any other dully appointed as its replacement.
3.    Landlord will facilitate a manufacturing cold shell building ready for delivery on the Property in Zona Franca Coyol no later than November 30th 2015, known as Multitenant twenty-six 

26, and it shall lease to the Tenant the Premises, as described below.  Such delivery shall be effective if lease agreement is executed no later than August 7th, 2015; if lease agreement execution date is delayed, then final delivery date will be delayed on the same amount of days.
4.    Tenant shall have the following purchase options from the effective delivery date of the premises of this Lease Agreement in which to decide if it will execute such options under the following conditions:
		
	i)
	Purchase Option No.1: Valid only during month twelve (12) of the "Lease Agreement" under the following conditions:

		
	•
	Fixed amount equivalent to US$3,495,000.00 

		
	•
	Fixed price amount of US$3,495,000.00 already includes a credit equivalent to US$112,000.00 regarding ground works performed at Lot 11, and a credit equivalent to US$118,000.00 regarding 12-month lease payment.

		
	ii)
	Purchase Option No. 2: Valid only between day one (1) of month thirteen (13) and last day of month twenty four (24) of the Lease Agreement under the following conditions:

		
	•
	Alternative A): "Price Match" offer in case of a third party buyer (investment fund or similar) is interested in property, Landlord grants the opportunity for Tenant to match de price offer.

		
	•
	Alternative B): If no formal interest is shown from third party buyer (investment fund or similar) to buy the property from Landlord, then Landlord grants Tenant the option to purchase the property under the following scheme: the total sum equivalent to the following twelve months of rent divided between an 8% cap. rate. 

		
	iii) 
	Tenant acknowledges and agrees that in order to execute any purchase agreement of the premises, Landlord must constitute a sub-condominium, which requires at least eight months for approval from governmental and municipal authorities.  As a result any purchase notice shall be communicated to Landlord with at least eight months in advance in order to create the subcondominium.

		
	iv) 
	All legal fees and transfer taxes related to property transfer will be paid on equal parts by both parties, nonetheless, any purchase option execution and/or public deed shall be done through a Public Notary defined by Landlord.  The Notary Public may be determined by any financial institution procuring the finance for the purchase by Tenant, if they so require.

-2-

Now therefore in consideration of the mutual considerations and promises herein made, and in consideration of the representations, warranties, and covenants herein contained, the Parties have agreed to execute this lease agreement (hereinafter referred to as the "Lease Agreement"):
Section One: Of the Leased Real Estate or Premises 
		
	1.00
	Leased Real Estate or Premises 

Landlord shall deliver and lease to Tenant, no later than November 30th 2015 after Lease Agreement Execution, a Cold Shell Manufacturing Building within Zona Franca Coyol, as shown in Exhibit Two and as described in Exhibit Three, and it shall lease Tenant an area of two thousand five hundred and ninety two (2,592.00) square meters (approximately 27,900.00 square feet), hereinafter the "Premises".
Landlord shall deliver the Premises to Tenant in accordance with the Landlord's "Shell Building Scope of Work" attached hereto as Exhibit Three.
		
	1.01
	Permitted Use 

The Premises will be used only for the purpose of installation and operation of a manufacturing facility and warehouse for manufacturing, marketing and commercialization of medical devices and related products.
The Tenant shall not alter the stated use of the Premises without the express written authorization of the Landlord.  In accordance with the Lease Agreement, Tenant shall at all times comply with all the applicable national, municipal and other governmental regulations in the carrying out and execution of its activities, including without limitation, Health Ministry regulations, Free Zone regime, environmental (i.e. SETENA) and customs regulations.  Tenant shall also comply with any Condominium regulations in effect, as attached hereto as Exhibit Four, or any future regulations or resolutions approved in accordance with Condominium by-laws.
Lessee shall not use the Premises for any illegal activities such as, but not limited to: sports-booking or gambling activities, manufacture of arms or parts thereof, or tobacco products.  These prohibitions will extend to any and all successors or assigns, as well as any prohibition stated in the Costa Rican Free Zone Regime Law.
		
	1.02
	Premises Conditions

Landlord shall deliver the Premises to Tenant on November 30th 2015 upon the Execution of this Lease Agreement, premises delivery is subject to the execution of this Lease Agreement no later than August 7th, 2015.  Any delay on the Lease Agreement execution will impact on the same amount of days the delivery of the premises.
Tenant understands and accepts without objections, the contents of Exhibit Three, and hereby acknowledges and accepts that any changes in the scope and contents of Exhibit Three may result in a change in the Date of Delivery as defined in Section 2.02 below.  In case of any extension in the 

-3-

Date of Delivery caused by Tenant, the Tenant will have to begin to pay Rent on the Rent Commencement Date as established in Section 2.00.
		
	1.03
	Tenant Construction and/or Improvements to the Premises after delivery to Tenant by Landlord.

Tenant may request changes to the Premises, subject to Landlord's written and prior approval, by providing written request to Landlord, hereinafter referred to as the "Change Notice".  Landlord shall have ten (10) business days after the receipt of any Change Notice, to approve or reject totally or partially the changes requested, if such changes result in an impact to project budget and/or schedule then parties shall approve new budget and/or schedule in writing.
Tenant may execute the changes directly, in which case, construction permits must be submitted to Landlord before the start of construction works.  Also Tenant can request Landlord to execute the works in which case Landlord will provide a change order form including an estimation of the cost and time of delivery of the changes requested by Tenant (Hereinafter referred to as "Change Order").  Costs will be estimated based upon the total direct construction costs of performing the changes, plus an additional fee of thirteen percent (13%).  This fee covers only the administrative costs incurred by Landlord, as well as the design, inspection and construction management of the change order scope of work.  Tenant will have five (5) business days to accept or reject the proposal given by the Landlord.  Costs due to Change Notices, Change Orders and its resulting works shall be paid by in full by Tenant concurrently with the acceptance by Tenant of such Change Order.  Any works resulting from an approved Change Order shall be carried out by Landlord or a subcontractor selected by Landlord to carry out the specific changes requested by Tenant through the Change Notice.  Landlord shall not perform the changes as per the Change Order, until the Change Order has been accepted by Tenant, in accordance to the terms agreed in such Change Order.  The Parties will agree a time schedule for the completion of the Change Order; however delays due to the agreed terms of the Change Order will be considered Tenant's Delay.  Changes to the premises made either by Tenant or through a Change Order shall have no impact on the Commencement Date as defined herein or on the term of this Lease Agreement, unless both Parties agree otherwise in writing.
Upon termination due to any cause of this Lease Agreement any works associated to a Change Notice and Change Order shall remain at the Premises; Landlord shall not pay any price nor reimburse any costs associated with the works derived from a Change Notice and a Change Order.
Tenant will be responsible for obtaining the appropriate permits as required by any applicable authority, including without limitation SETENA and PROCOMER, for Tenant's Work (defined as any work performed under Tenant's direct responsibility by its employees or subcontractors).  Landlord will cooperate with Tenant diligently in the application of all such construction permits for Tenant's Work.  For these purposes, Landlord shall execute all documents and forms and provide informational documents that are required by public authorities from the owner of the Property in order to obtain any arid all required permits.  The costs for all permits for Tenant's Work will be Tenant's responsibility.

-4-

		
	1.04
	Parking 

In addition to any other facility specifically included in this Lease Agreement, the Premises include eighteen (18) parking spaces and one (1) truck dock, located in the perimeter of the Premises, outlined by road demarcations according to the country's and Zona Franca Coyol standards; additional spaces can be rented at the then current monthly rate for parking spaces in Zona Franca Coyol determined by Landlord, and subject to availability.  The Tenant will be responsible for assigning as many parking spaces as he deems necessary within the eighteen (18) parking spaces assigned to it, for use by its VISITORS and required by Law 7600.
		
	1.05
	Condominium Common areas.

The Tenant can make use of Coyol Free Zone's common areas according to the regulations and specifications included in the Condominium By-laws in its current form, and including any subsequent amendments.  The current form of these regulations has been enclosed as an integral part of this Agreement as Exhibit Four, however since all common areas shall be subject to the exclusive management and control of the Landlord, Landlord reserves the right to modify, alter or enlarge common areas, or their use, within the Condominium By-laws, to its sole discretion provided Tenant's rights as per this Lease are not materially affected.
		
	1.06
	Special systems, equipment and additional constructions to Premises 

Once Building has been delivered to Tenant, Tenant may request at its own expense, the installation of certain special systems and equipment in the Premises in accordance with the Condominium By-laws.
If Tenant decides to carry out any additional works in the Premises, that will not damage or alter the property, it may do so, provided it has submitted to the Landlord before commencing any such activities, all the required construction permits.  Landlord will cooperate with Tenant in the application of all such permits.  Works in the Premises that will become affixed to it, or change it permanently, or cause damage to it are not accepted, unless Landlord has provided Tenant written consent that cannot be unreasonably denied or withheld and the permits indicated above have been provided.  Furthermore, Tenant shall be responsible to cover any costs associated with obtaining such permits, including but not limited to any applicable taxes.
If Tenant wishes to remove any of the additional systems and/or equipment installed in the Premises after the Building has been delivered to Tenant, Tenant shall perform all necessary works, at its own expense and as per Coyol Free Zone instructions and approval, to return the premises to the conditions in which they were received by Tenant as per Exhibit Three.  All costs related to Tenant's equipment removal and repair of Premises shall be paid by Tenant.

-5-

Building Automated Fire Protection System will be installed within the premises by Landlord at an additional cost of fifty eight thousand seven hundred and sixty nine dollars with seventy two cents ($58,769.72), which will be paid by Tenant to Landlord under the following to options:
i)    Single payment at Rent Commencement Date for the total amount of fifty eight thousand seven hundred and sixty nine dollars with seventy-two cents ($58,769.72).
ii)    Landlord will finance the installation of such system at a 10% annual rate for a period of ten years, if Tenant decides to move forward with this option it shall pay a monthly installment equivalent to seven hundred and seventy-seven dollars (US$777.00) during ten years.  Payment must be done at the same time as the monthly rent payment.  If an anticipated termination of the Lease Agreement on behalf of the Tenant shall occur, then Tenant shall pay to Landlord the outstanding balance at the moment of such anticipated termination.
		
	1.07
	Building, Systems and Equipment guarantee 

Landlord shall complete the Premises (and any improvements thereto) in accordance with the plans or the description of improvements attached as Exhibit Three, attached hereto.  All necessary construction shall be "Substantially Completed," ready for use and occupancy by Tenant, subject to extension for delays due to Force Majure, Acts of God or any other excusable delay as per the terms of this Lease Agreement.  Landlord represents and warrants that all construction shall be done in a good and workmanlike manner.  The Premises will be as of the date delivered to Tenant in good working order and condition, including without limitation, the Cold Shell Building and plumbing system are brand new, the roof free of leaks and that they have been built and/or installed as per Construction Code, Equipment and Systems Manufacturer instructions and all applicable laws of Costa Rica; as a result the Premises, its systems and equipment are covered by the guarantee terms established in the applicable Costa Rican laws.
The work which Landlord is required to perform shall be deemed "Substantially Completed" or "Substantially Complete" when it has been completed to a degree that no portion thereof remaining incomplete is so material that it would prevent Tenant from occupying the Premises and conducting its business therein (as per contractual building specifications agreed by parties), nor would it prevent the Premises from being lawfully occupied.  At the time Landlord's work is Substantially Completed, a representative of Landlord and a representative of Tenant will perform a walk-through inspection of the Premises and will prepare a punch list if one is necessary of minor items remaining to be furnished, repaired or replaced.  The representatives of the parties preparing the punch list will both sign the punch list, and Landlord will cause work on all items listed on the punch list to be performed within twenty (20) days after the Rent Commencement Date (as defined in Clause 2.0 below).
Parties have agreed to exclude from "Substantial Completion" scope of work the concrete floor of the Cold Shell Building due to construction strategy; as a result a total of US$104,000.00 will be credited in favor of the Tenant into the Improvements Construction Management Agreement to be executed among parties.

-6-

Section Two: of the Rent and Lease Term 
		
	2.00
	Rent 

The base monthly rent (the 'Rent') payable on the Rent Commencement Date shall be of ten dollars and eighty-five cents (US$10.85), legal tender of the United States of America, per leased square meter, for a total of twenty eight thousand one hundred and twenty three dollars with twenty cents (US$28,123.20).  The rent amount is net of any current or future applicable taxes during the term of the lease, any future applicable taxes will be under Tenant's responsibility.
All Rent and other fees indicated herein shall be payable, within the first five (5) days of each month, at the rate indicated herein for the first year of the Lease Term.  Starting with the end of the 12th month following the Rent Commencement Date, until expiration of the Lease, any payments to Landlord shall increase by five per cent (5%) from each anniversary of the Rent Commencement Date and until the expiration of this Lease Agreement, using as basis for such increase the amount effective the previous year.
The parties have agreed that Tenant will be exempt of rent payment for the duration of the construction period of the Cold Shell Building.  Parties have agreed that the "Rent Commencement Date" will be the date that Landlord delivers and Tenant accepts a "Substantially Completed" Cold Shell Building and Improvements (provided CMA is executed between Tenant and Landlord) to Tenant; all other fees and costs derived from this Lease Agreement shall be paid by Tenant to Landlord taking into consideration the Rent Commencement Date as starting point (i.e. no grace period granted to Tenant).
Furthermore, starting on the Rent Commencement Date, Tenant shall pay the following fees:
a)    A monthly service fee of thirty two cents of dollar (US$0.32), legal tender of the United States of America, per leased square meter of construction area for a total monthly service fee of eight hundred twenty nine dollars and forty four cents (US$ 829.44) in accordance with Exhibit Six of this Lease Agreement, as of the Rent Commencement Date, monthly service fee yearly increase shall not exceed five percent (5%).
b)    Tenant will also pay all condominium fees, including ordinary and extraordinary fees as provided by the Condominium General Assembly.  Current Ordinary Condominium monthly fee has been established at the current rate of US$0.614 per [eased square meter of construction area for a total ordinary monthly fee of one thousand five hundred and ninety one dollars and forty nine cents (US$1,591.49), legal tender of the United States of America.  The monthly ordinary fee is subject to changes established by the Condominium Owners General Assembly; Tenant must pay the current-at-the-time ordinary condominium fee established by the Condominium Owners General Assembly and Landlord shall not indemnify Tenant in any form as a result of these increases.  If such fee surpasses US$0.614 per leased square meter provided herein, it shall be increased equally.
c)    Tenant will also pay any extraordinary condominium monthly fee as provided by the Condominium Owner's General Assembly at the rate established per leased square meter of 

-7-

construction area.  Tenant must pay any increases in this extraordinary condominium fee established by the Condominium Owners General Assembly and Landlord shall not indemnify Tenant in any form as a result of these increases.
The Condominium fee includes the following services:
i)    Free Zone Perimeter security twenty four hours a day, all year round, including a) Access Control, b) Video Cameras at the vehicle and pedestrian access and its related equipment maintenance, and c) Perimeter Security.
ii)    Common Area Maintenance –  CAM: a) cleaning of streets and Condominium common areas such as bus stops, sidewalks and common parking areas; b) maintenance of common gardens and green common areas (includes water fees only for these areas); c) Maintenance of original building's landscaping and green areas (any modifications or special requirements must be paid by the Tenant); d) access to wastewater treatment plant usage as per Wastewater Treatment Plant Usage Regulations (Exhibit Five); e) maintenance of sewer, potable and storm water pipes; f) general maintenance of infrastructure (sewer system, fiber optics and potable water system); h) Coordination service for exclusive bus transportation for the employees of the park.
The Condominium fee does not include the following services:
i)    Any costs of utilities or any other installations or services for the Premises utilities, not included in the additional monthly service fee as per Exhibit Six, including, without limitation, electricity, telecommunications and water, which shall be paid by Tenant in accordance with applicable fees, and usage shall be determined by the meters specifically installed for such purpose by the carriers of these services, or installed by Landlord, if necessary.  Tenant acknowledges that third parties provide utilities and telecommunication services; as a result Landlord is not liable for any consequences on Tenant's operations or activities due to any interruption in such services.
ii)    Condominium fee does not include any cost of repair or replacement of any of the items or systems listed above when damage is derived or caused by Tenant, its employees, subcontractors or third parties hired by Tenant and Tenant will be responsible for all such related costs of repair and/or replacement of any damaged items or systems.
iii)    Water consumption for Premises green areas is not included in Condominium Fee, Tenant shall be responsible for cost of its own water consumption including Premises irrigation system.
iv)    Electronic Access ID cards for its employees.  The original cost for each ID card is estimated at eight (8.00) dollars, legal tender of the United States of America, per card.  All repositions of electronic access ID cards will be charged at twenty (20.00) dollars, legal tender of the United States of America, per card.

-8-

Garbage collection fee is not included in the Condominium fee; as a result garbage collection service has been established at the following monthly rate: US$30,00 for each five (5) cubic meter garbage container rent and US$30,00 for each garbage collection per container.  Since Tenant premises are located on a Multitenant Building, all building users share garbage collection, as a result Tenant shall pay a prorated sum (based on premises area) of such amount on a monthly basis to Landlord on the same day of the rent payment.  Condominium Owners General Assembly establishes garbage collection fee based on external contractors, as a result fees are subject to change at least once a year.
All payments derived from this Lease Agreement shall be made on the first five (5) days of the month, and in their full-stipulated amount, without any deductions.  If a value added, sales tax, service tax, or any new tax where to be applied to any of such payments during the term of this Lease Agreement or applicable extensions, Tenant shall be obligated to increase the amount paid in order to cover such taxes, so Landlord will continue to receive its current rent net of value added taxes or any other similar government mandated charge.
All payments shall be made in cash, check from a bank of the Costa Rican national banking system, or electronic transfer to the Landlord's account.  The validity of any form of payment different than cash remains subject to its approval and final credit in favor of Landlord.  In case of wire transfers, the Tenant shall notify in writing to the Landlord, the date in which the transfer was executed, and such payment shall be deemed made on the date on which the transfer is credited by the Landlord's bank.  The wire transfer information is attached hereto as Exhibit seven.  All applicable transfer fees or bank charges must be paid by the Tenant.  For purposes of this Agreement, the Tenant's address shall be the address in effect where payments should be made.  In the event that the beginning or end of the term of this Lease is not the first of a month, rent shall be prorated such that Tenant shall only pay the portion of the rent allocated to the portion of the month the Premises are occupied by the Tenant.
Tenant shall be responsible to include under monthly fees payment any ordinary monthly fee increase and extraordinary monthly fee established by the Condominium Owner's General Assembly for year 2015 and beyond.
The totality of the monetary obligations contained in this section shall be considered part of Tenant's basic obligation to pay rent, in accordance with articles twenty five and sixty four of the General Urban and Suburban Lease Law in effect in Costa Rica.
		
	2.01
	Term of the Lease 

The term of the lease shall be ten (10) years (the 'Lease Term'), commencing on the Rent Commencement Date.  Tenant shall provide written notice to Landlord within one hundred and eighty (180) days before Lease Term expiration if it wishes to extend the lease for two years under consistent terms.  The term may thereafter only be renewed by mutual written agreement of both parties.

-9-

Parties hereby expressly waive the automatic renewal provided in article 71 of the Costa Rican Leases and Subleases Act (Ley General de Arrendamientos Urbanos y Suburbanos).
		
	2.02
	Date of Delivery and Legal Effect of the Agreement 

The Landlord will deliver a Substantially Completed (as defined in Clause 1.07 above) Cold Shell Building to Tenant no later than November 30th, 2015 provided the execution date of this Lease Agreement takes place before August 7th, 2015.  If delivery of Cold Shell Building to Tenant by Landlord is delayed more than three months after the original delivery date, Tenant shall have the right to terminate the Lease Agreement.  If parties agree to execute the CMA for Cold Shell Building improvements (within two weeks of Lease Agreement execution) then Date of Delivery shall be deemed as the date when Cold Shell Building and Improvements is delivered to Tenant.  Such delivery shall occur as per the master schedule delivery date agreed on the Improvements CMA Agreement.
Notwithstanding anything to the contrary in this Lease, Tenant's acceptance of the Premises shall not be deemed a waiver of Tenant's right to have defects in the Premises repaired at Landlord's sole expense.  Tenant shall give notice to Landlord whenever any such defects become reasonably apparent, and Landlord will use its best efforts to repair such defects within twenty (20) days after receipt of written notice from Tenant; unless otherwise agreed among parties.
The rights and obligations of Tenant to enter the Premises shall be effective upon the Tennant's acceptance of the Delivery of the Premises.  Legal effects regarding the use and enjoyment rights, as well as Tenant's rights and obligations as park tenants shall commence as of the execution of this Lease Agreement.
		
	2.03
	Delays not Attributable to the Tenant 

In accordance with Article 705 of Costa Rican Civil Code, the Tenant guarantees and acknowledges that it will not file any lawsuits or claims to recover additional amounts from the Landlord originated in a failure to deliver the Premises in a timely manner for causes not attributable to the Landlord, its contractors, agents or employees.  Tenant accepts that it shall not file a claim against the Landlord or attempt to collect any losses, damages, penalties, expenses, disbursements or amounts, including but not limited to, legal fees or expenses, request a sum for damages or losses, if due to Force Majeure, acts of God, or other causes not attributable to the Landlord, if it's not possible to deliver the property on the date convened herein.
		
	2.04
	Security Deposit 

Tenant will provide Landlord a security deposit through a local bank guarantee, letter of credit or cash deposit, equivalent to the amount of thirty thousand three hundred and fifteen dollars (US$ 30,544.13), an amount equivalent to one (1) month's rent at the moment of execution of this Lease Agreement.  After the Cold Shell Building is Substantially Completed, or, in the event the Improvements CMA is executed between the Tenant and Landlord, after the Cold Shell Building Improvements are Substantially Completed, Tenant will provide Landlord the security deposit 

-10-

mentioned above in cash if such security deposit was provided to Landlord through a local bank guarantee at the execution of this Lease Agreement.    Such security deposit shall serve as security for this Lease Agreement, and such amount shall be retained by Landlord as a security deposit for the purposes described in this Agreement (the "Deposit").  The Deposit shall serve as a guarantee to cover the payment of outstanding services, repairs and any other obligation derived from this Agreement and contractually or legally owed by Tenant, to the Landlord's satisfaction.  The Landlord shall have the right, but not the obligation, to use the Deposit to settle due outstanding rent payments.  Tenant authorizes Landlord to use the Deposit to cover the expenses of obtaining construction permits for additional construction works requested by Tenant, provided such permits are not included in either the Rent or the Service or Condominium Fee.  If all or part of the Deposit were used by the Landlord for any of the aforementioned items, the Tenant shall have an obligation to reinstate the used amount within five (5) calendar days following notice of its use by the Landlord, unless such use is made upon termination of the lease, in which case the remnant, if any, shall be returned by the Landlord to the Tenant in the thirty (30) calendar days following the date on which this Agreement is terminated, provided Tenant presented evidence satisfactory to the Landlord, that all utilities bills corresponding to the Tenant are fully paid.  The Deposit shall not bear any interest for the benefit of the Tenant.
The security deposit shall be properly deposited in Landlords bank account in order to have this Lease Agreement effective.
Upon termination of the Lease, Landlord will withhold from the Security Deposit any unpaid obligations of Tenant to Landlord under the Lease Agreement, including utilities, and refund to Tenant the balance of the Security Deposit within sixty (60) days, subject to the conditions provided above.
Section Three: Tenant's Rights and Obligations 
		
	3.00
	Restrictions of the Premises 

The Tenant:
a)    shall not modify the purpose of the Premises without prior authorization of the Landlord:
b)    shall not carry out within the Premises, any type of activity that produces unreasonable or illegal noises, smells or materially disturbing activities to other occupants of Coyol Free Zone or other neighbors of the area where the Premises are located;
c)    accepts that the activities performed in the Premises shall not produce emanations that can adversely affect the environment or people's health, and that the execution of such activities shall at all times comply with the corresponding local and national regulations;
d)    shall not use the Premises for the storage of flammable or dangerous substances, materials or chemicals unless such substances, materials or chemicals are used in their 

-11-

manufacturing operations or are stored according to any and all applicable safety standards, Condominium Regulations and applicable law.  In other cases, the Tenant must communicate in writing such circumstance to the Landlord, including a list describing such items.  The substances, materials, or chemicals should be properly stored in accordance with the applicable laws, regulations, and any other safety provisions.
e)    Sewage Treatment Plant.  The Condominium has a residual waste water disposal plant which is designed to be used by all the Condominium Tenants.  However, in order for the Tenant to use the facilities of such plant, it must abide by the conditions and requirements regarding the types of water that may be disposed of into the plant (Exhibit Five).  Any violation of such conditions and requirements by the Tenant endangers the environment and the status of the Condominium general population and will therefore inhibit the Tenant to continue using the facilities, as well as to force it to pay any and all amounts required to fix, clean or recalibrate the plant back to its normal conditions as established in such Exhibit Five; this use of the sewage treatment plant is included in the Condominium Fees as established in section 2.00 of this agreement.  Any damage caused directly or indirectly by Tenant, its employees, subcontractors or third parties to Sewer System originated by inadequate disposal of items such as but not limited to: gloves, personal ID badges, cell phones, head covers, booties, paper towels, tools or any other item related to Tenants activities within the Premises, will be paid by Tenant.
		
	3.01
	Coyol Free Zone Regulation 

The Tenant shall respect at all times Coyol Free Zone's Internal Regulations, and the Condominium Bylaws, in its current text and its amendments.  Said regulations, which the Tenant recognizes and accepts, are hereby attached to this Agreement as Exhibit Three.
		
	3.02
	Repairs and improvements 

The Landlord shall be obligated to maintain, at its own expense, the Premises in general, including but not limited to, the exterior structural elements, exterior pluvial, and sewage water systems, as well as pay for all other maintenance fees or repairs derived from the normal wear and tear of the exterior of the Premises, including roof and parking spaces, or any other repair or maintenance of the Premises not caused directly or indirectly by the actions of Tenant or Tenant's subcontractors.  Maintenance of existing equipment, as well as procurement of spare parts and replacements within the Premises shall be Tenant's sole responsibility, such maintenance shall be performed in an optimal way to operate and preserve the equipment, by Tenant or third parties approved by Landlord; a biannual report must be presented by Tenant to Landlord on all maintenance activities performed on existing equipment within the premises.  The Landlord shall cooperate with Tenant to enforce all such guarantees with respect to the Premises which will reduce Tenant's maintenance obligations, and shall not be obligated to maintain at its expense the interior and improvements of the Premises in general, even if such maintenance could be considered as necessary because of the normal wear and tear of the inside of the building, unless otherwise stated in the Lease.  The Tenant shall bear the cost of any other repair such as broken glasses, burnt light bulbs, gaskets and, generally, any service accessory or accessories incorporated to the Premises.  Any damages or repairs caused or generated by the Tenant's negligence or willful misconduct shall 

-12-

run at the Tenant's expense, as well as all of the secondary elements added to the Premises by the Tenant.  Notwithstanding the foregoing, the Tenant shall not, without the prior written consent of the Landlord which shall not be unreasonably withheld or delayed, make changes or adjustments to the Premises, even if related to indoor or outdoor maintenance works.  It shall not be necessary to obtain prior consent from the Landlord to make indoor changes, adjustments or maintenance works whenever these do not affect the Premises' structure or are not permanently affixed to the same.  The Landlord shall respond to any request for approval of changes or adjustments to the Premises within ten (10) calendar days of its receipt of such request.  If authorization is received, all improvements made by Tenant, shall be for the benefit of the Landlord, without giving rise to the Tenant to request a deduction in the rent or an economic compensation for these upon termination of the lease's term.  Except that Tenant shall have the right to remove: (i) its trade fixtures and business equipment, and (ii) any other equipment installed by Tenant in or about the Premises, whether or not affixed to the building.  If such changes, adjustments or improvements may cause the Premises to suffer any damage Tenant has two options: (i) leave the improvements to the benefit of Landlord or (ii) repair Premises of any such damages immediately, at its sole cost and expense.  In case Landlord has consent to an improvement of the Premises and provided such improvements increase the market value of the Premises, increase in payment of land tax, due to such increase in market value, shall be compensated by Tenant to Landlord through an increase in the monthly rate payment.
		
	3.03
	Responsibility for damages 

The Tenant shall be (i) liable for any damage or loss incurred to or suffered by the Premises and equipment, which is caused by or attributable to its employee's, officer's and/or agents', or by third parties' or client's that visit or use the Premises and shall be (ii) responsible for the damages caused, by any of the aforementioned individuals, to common areas of the Coyol Free Zone.
Any form of damage caused by the Tenant, or any of the aforementioned individuals in this clause, shall be repaired by the Tenant, at its own expense, without the right to demand from the Landlord a reimbursement or cost deduction from the lease.
Repairs shall be initiated within a term no greater than eight (8) calendar days, except in cases of emergency, whereby they should be fixed immediately, allowing the Tenant to hire the workers it deems suitable.  Prior to making the repairs, and except in cases of emergency, Tenant shall have the approval in writing of the Landlord with regards to quality and work to be performed, such approval shall not be unreasonably withheld.  In such cases, the Landlord must respond within the following twenty-four hours following the receipt of a written communication by the Tenant.  Should the Landlord not respond within the aforementioned time frame, the authorization will not be deemed granted, but the eight (8) day period will not begin until the day after an affirmative response is rendered by the Landlord.  If plans for repair works have not been initiated in the aforementioned term, the Landlord shall provide written notice to the Tenant of said noncompliance and it shall provide to the Tenant a cure period of eight calendar days ("Cure Period") to initiate the repairs.  If the Tenant does not initiate the repairs within the Cure Period, the Landlord may request the termination of the Agreement due to non-fulfillment and/or is fully authorized to deduct from the Deposit the necessary amount for repairs, and perform them on behalf of the Tenant.

-13-

By virtue of this clause, the Tenant's liability is comprehensive and includes any violation acts to the legal system, caused by Tenant's activities in or use of the Premises, whether by its employees, officers and/or agents or by third parties or clients that visit or use the Premises, may these be civil, labor, environmental, health-related or any other sector, even when these acts are not subjected to an economic compensation.
		
	3.04
	Accidents 

Except to the extent resulting from negligence or willful misconduct of one party's employees, contractors, agents of invitees, as the case may be, such party does not assume civil, penal, labor, or any other type of responsibility, for damages or losses incurred to the other party or third parties; notwithstanding the foregoing, in no event shall the Tenant or Landlord be liable for business losses or indirect damages, motivated or as a consequence of accidents caused by the other party, its agents, contractors, employees or invitees, as well as due to force majeure, during the effective term of this lease agreement and its possible extensions, except for those consequential damages by Tenant, related to Free Trade Zone matters that economically affect the Landlord.
		
	3.05
	Subleasing and Assignment of Rights 

The Tenant may sublease or assign this Lease Agreement, or the rights derived from it, obtaining the Landlord's prior and written consent, to its affiliates, subsidiaries, or branches, provided that i) the Tenant demonstrates the existing relationship; and ii) the assignee or subtenant accepts to be bound by this Lease Agreement.  Tenant shall remain jointly and severally liable against Landlord for all obligations in this Lease, not limited to monetary terms and conditions, and any already provided guarantees provided for the original Tenant, shall remain in favor of new tenant until the Termination Date of this Lease Agreement.  Otherwise, the Tenant may not sublease the Premises, nor fully or partially assign this Lease Agreement without the prior written consent of Landlord.
Landlord may assign this Lease Agreement, or the rights derived from it totally or partially to a third party without the Tenant's prior or posterior consent or approval, provided that: (i) it gives notice to Tenant of such assignment; and (ii) no such assignment shall affect or modify Tenant's rights and obligations under this Lease Agreement.
		
	3.06
	Acquisition of Permits 

The Tenant shall be responsible to process and acquire all those permits necessary for its operation, in addition to the performance of activities carried out within the Premises, such as, but not limited to, those permits and authorizations necessary for operating under a free zone regime.  In the event that the Landlord authorizes any renovations or improvements required by Tenant on the property, the Tenant shall assume the costs, exclusively, for the permits, authorizations and other necessary acts for their execution, including any increases in payment of land taxes, due to Tenant's improvements.  The Landlord shall cooperate with the Tenant in the acquisition of the corresponding permits or authorizations whenever its assistance is required for such purpose, and shall maintain all taxes and permits paid and up to date.

-14-

		
	3.07
	Signage 

The Tenant shall not place, or allow the placement of signs or notices of any type, in any exterior area of the building or common areas of the Coyol Free Zone, other than the clearly designated sites by the Landlord for these purposes, and shall provide proper maintenance to such signs, so that they are in perfect condition always.  Moreover, the Tenant shall comply with the signage specifications included in the Condominium Bylaws or other applicable documents to the Tenant by virtue of the present agreement.
		
	3.08
	Notice of failures or accidents to the Landlord 

Except to the extent resulting from negligence, hidden defects or willful misconduct of the Landlord as the case may be, the Landlord does not assume civil, penal, labor, or any other type of responsibility, for damages or losses incurred to Tenant or third parties.  Notwithstanding the foregoing, in no event shall the Landlord be liable for losses, motivated or as a consequence of accidents caused to it due to the Tenant's responsibility, fraud or fault, as well as due to force majeure, during the effective term of this lease agreement and its possible extensions.
		
	3.09
	Compliance with the laws and applicable regulations 

Unless otherwise established in this Lease, both parties shall comply with applicable laws at its own cost and expense, and execute, whenever the case, the provisions of any laws, ordinances, rules, orders, acts, regulations, and legal requirements in effect applicable to the respective party regarding the Premises and the activities that Tenant will perform in the Premises.  In particular, but not limited to, both parties shall comply with the corresponding and applicable provisions of the Law of the Free Zone Regime and its regulations, as well as the Customs Law and its regulations.  There shall be no liability under this Lease against Landlord for consequential damages, including but not limited to loss of profits.
		
	3.10
	Prohibition of Common Areas Obstruction 

The obstruction of common areas of the Coyol Free Zone with equipment, vehicles, machinery, raw material or any other goods owned by the Tenant or his/her contractors, employees, dependents or visitors, or any other person related with him/her, is expressly prohibited.  The Tenant must always supervise that common areas are free from obstructions caused by any of the persons mentioned in this clause.  Particularly, the parking of vehicles owned by the Tenant's personnel or visitors in the main streets of the Coyol Free Zone is expressly prohibited.  The Tenant accepts to pay a twenty five dollar fine per incident for parking and/or obstruction violations of these provisions, plus the cost of the obstruction removal resulting from the non-compliance with this provision.  The amount corresponding to the fine shall be charged with the Rent corresponding to the next month.
		
	3.11
	Prohibition of Transit Areas Obstruction 

-15-

Sidewalks, entrances, passageways, elevators, stairs, lobbies and other common transit areas may not be obstructed, used or occupied differently for the entrance or exit of machinery, material, equipment, vehicles or persons, depending on the case, related with the activities developed by the Tenant.  The Tenant must guarantee the compliance with this obligation on the part of his/her representatives, contractors, employees, dependents, visitors, and other related personnel, however noncompliance will generate the fine provided in Section 3.10 above.
		
	3.12
	Transfer of Material, Machinery, or Heavy Equipment 

The Tenant may not move any equipment, goods or heavy machinery in and outside the building without the suitable means to avoid damaging the constructions located in the Premises, and it must be done in coordination with the Landlord as established in the Condominium Bylaws.  Landlord shall not unreasonably delay or deny such movements required by Tenant.  Any damage resulting from the movement of the goods mentioned in this clause must be repaired by the Tenant pursuant to the terms established in clauses 3.03 of the present Agreement.
		
	3.13
	Other commitments 

Tenant shall: a) commit to the Condominium By-laws, and Park Regulations as available at Landlord, and it shall remain a beneficiary of the Free Trade Zone Regime at all times, and keep all requirements to qualify as such in order and current, as long as its role as beneficiary is required by law in order for Landlord to obtain and maintain benefits as Park Administrator; b) Upon termination of the Lease Agreement, Tenant may remove any and all Tenant improvements at Tenant's expense, and will retain ownership of same, provided any damages to the Premises due to such removal, are repaired by Tenant, subject to Section 3.02.  Tenant improvements not removed by Tenant will become the property of Landlord.  Tenant agrees to pay for the removal and disposal of any Tenant improvements that Landlord does not wish to keep, at Tenants sole cost and expense.  Upon Termination, Landlord will inform Tenant in writing of the cost of such works and Tenant will then have a term of seven calendar days to respond, in writing, if it agrees Landlord makes such repairs, or if it wishes to make them itself.  Failure to respond shall be deemed and acceptance of the performance of the works by Landlord.  If Landlord performs the works after Tenant's acceptance, Tenant shall reimburse Landlord all costs and expenses of such works in the term of ten (10) working days after works have been performed; and c) Allow the Landlord and / or PROCOMER to inspect and visit the Premises during normal business hours as well as to inspect any and all materials, merchandise, and assets in order to fulfill their control responsibility; provided, however, three (3) days' notice is provided to Tenant.
Section Four: of the Landlord's Rights and Obligations 
		
	4.01
	Payment of Taxes 

The Landlord shall pay all applicable municipal and real estate taxes for the Premises, and all taxes required for the correct operation of the Coyol Free Zone.  The Tenant shall pay all applicable taxes for its own activities to be carried on the Premises during the term of this Lease Agreement, 

-16-

and any increase to the municipal and real estate taxes derived from any and all improvements by the Tenant or on behalf of Tenant.
		
	4.02
	Inspection Right 

The Landlord reserves the right to visit the Premises any moment, provided that they inform the Tenant at least seventy two (72) hours in advance.  Inspections referred in this clause must be done during Tenant's working hours, through its officers or third parties hired to that effect.  Exceptionally, with prior authorization by the Tenant, inspections may be carried out off the regular working hours.  Landlord shall comply with Tenant's confidentiality requirements, security precautions and health and safety requirements during any such entry.
		
	4.03
	Ownership of the Goods Left in the Real Estate 

After fifteen calendar days of the last day Tenant pays to rent according to Section 5.01, or after the termination date of the present Agreement, for any cause imputable or not to the Tenant, or in case of eviction for non-compliance with the payment, whatever happened last, if Tenant has not vacated and delivered the Premises back to Landlord, Tenant shall pay Rent for such fifteen calendar days at a rate that shall be the current applicable Rent multiplied by 1.5, and Tenant may continue to pay such Rent until it vacates such Premises, for a maximum term of thirty calendar days since the termination date.  After such thirty calendar day term, the Premises shall be deemed vacated, and any goods owned by the Tenant found inside the Premises or in the common areas of the Coyol Free Zone shall be considered abandoned by the Tenant.  Therefore, the Landlord may take possession of the same.  The Tenant waives any right to seek any compensation resulting from such circumstance.
		
	4.04
	Showing of Facilities 

Prior to the termination of the Lease Agreement or any extension, the Landlord shall have the right to show the Premises to people interested in leasing or purchasing it, during the last six months of the term in effect.  The visits to show the Premises must be scheduled by the Landlord within Tenant's working hours, and shall only require a prior verbal communication to the Tenant.  In case any such showing does involve any third party that Tenant demonstrates to Landlord is, might be or might cooperate with a competitor of the Tenant, Tenant can require Landlord and/or any third party to sign a confidentiality form prior to such showing.  Tenant shall be in no obligation of showing or explaining any such third party any part of its processes or operations or the purpose of any equipment found within the premises.  If any visit of Landlord may interfere with Tenant's production process, Tenant may reschedule such visit for a time when no interference would be caused within the next five (5) calendar days.
		
	4.05
	Entry Right on the part of the Landlord to Repair Damages 

The Landlord, its employees or contractors, shall have the right to enter the Premises in order to make repairs that might correspond to it, in accordance with this Agreement and the legislation in effect.  Nevertheless, the Landlord must previously coordinate with the Tenant the time in which such repairs shall take place, trying as far as possible, and pursuant to the particularities of the repair, 

-17-

that its execution must be done on the less prejudicial moment for the normal functioning of the Tenant's activities.
		
	4.06
	Right of Sale of the Real Estate 

Tenant shall have the following purchase options from the effective delivery date of the premises of this Lease Agreement in which to decide if it will execute such options under the following conditions:
i)    Purchase Option No.1: Valid only during month twelve (12) of the "Lease Agreement" under the following conditions:
		
	•
	Fixed amount equivalent to US$3,495,000.00 

		
	•
	Fixed price amount of US$3,495,000.00 already includes a credit equivalent to US$112,000.00 regarding ground works performed at Lot 11, and a credit equivalent to US$118,000.00 regarding 12-month lease payment.

ii)    Purchase Option No.2: Valid only between day one (1) of month thirteen (13) and last day of month twenty four (24) of the Lease Agreement under the following conditions:
		
	•
	Alternative A): "Price Match" offer in case of a third party buyer (investment fund or similar) is interested in property, Landlord grants the opportunity for Tenant to match de price offer.

		
	•
	Alternative B): If no formal interest is shown from third party buyer (investment fund or similar) to buy the property from Landlord, then Landlord grants Tenant the option to purchase the property under the following scheme: the total sum equivalent to the following twelve months of rent divided between an 8% cap. rate.

Subject to the provisions an limitations of this Section 4.06 and the Purchase Options established within this contract, the Landlord shall have the right to sell the Premises to any third party without prior or posterior consent or approval of the Tenant during the term of the Lease Agreement and the Lease Agreement will remain valid and in force as established in article 75 of the Costa Rican Leases and Subleases Act, provided that: (i) no sale shall affect or modify Tenant's rights and obligations under this Lease, (ii) Tenant shall have no obligations to subordinate this Lease to the interest of any mortgage, deed of trust, or collateral assignment to any third party that becomes the new owner of the Premises, and (iii) Landlord gives notice to Tenant of such sale once the public deed related to that sale has been executed.
		
	4.07
	Release of liability in case of accidents 

The Tenant releases the Landlord from any responsibility for any accidents resulting from electricity, flood, gas or any other phenomena resulting or not from the Premises usage, unless such 

-18-

were caused by the negligence or willful misconduct of the Landlord or hidden defects of the Premises.  Tenant shall indemnify, defend, protect and hold harmless Landlord from all damages, liabilities, claims, judgments, actions, attorneys' fees, consultants' fees, costs and expenses arising from the negligence or willful misconduct of Tenant or its agents, contractors, employees or invitees, or the breach of Tenant's obligations or representations under this Lease.
		
	4.08
	Release of liability in case of robbery or theft 

The Tenant discharges the Landlord from any responsibility for robbery or theft in the Premises, unless the same was caused by negligence or imprudence, as defined under the Civil Code of the Republic of Costa Rica, on the part of the Landlord or the security company contracted by the Landlord and could not have been reasonably prevented by the security company.
		
	4.09
	Non waiver of rights 

The fact that one party does not require compliance with any of the terms and conditions herein established, may not be considered as a waiver to the rights and actions granted by means of the present Agreement or the legislation applicable to the case.
		
	4.10
	Insurance 

Landlord shall have in place insurance policies for Premises and related equipment described in Exhibit Three; Tenant may contract, at its own expense, additional insurance policies in connection to Tenant's owned or leased equipment and improvements on Premises performed as per Tenant's request.
All costs related to insurance policies derived from events caused by Tenant or attributable directly or indirectly to Tenant, its employees, visitors or subcontractors shall be paid in full by Tenant.
Section Five: Termination of the Agreement 
		
	5.00
	Moment of Termination 

The Tenant shall remain obligated to pay Rent, as well as any other monetary obligations, and to comply with any terms and conditions of this Lease Agreement, until it has returned the Premises to Landlord, even if it has previously vacated the same.  The Premises shall be clean when delivered, with swept floors.  Return of possession will be deemed to occur when the Tenant returns all keys to the Premises and/or other parts of the Park if applicable.
		
	5.01
	Termination for convenience in advance on the part of the Tenant 

If prior to the delivery of the Premises, or at any time prior to the termination of the agreed term of this Lease Agreement, the Tenant wishes to terminate the Lease Agreement, it must provide prior written notice to the Landlord nine (9) months in advance of the expected termination date, and shall pay Landlord the equivalent sum of twelve months of rent as penalty for early termination.  

-19-

Additionally, Tenant shall continue to pay rent until a new Tenant occupies the premises, twelve months elapse, or the Lease Term minus twelve months is reached, whatever happens first.  Landlord will not return the security deposit to Tenant in case of anticipated termination of the Lease Agreement.
Tenant shall be free to negotiate the price of any improvements made to the building by Tenant with the new tenant under clause 3.02 terms and as long as Tenant is paying rent (building being occupied or not).  Once payments from Tenant to Landlord have ceased, Tenant's right to negotiate improvements with new tenant will be deemed expired.
Parties agree to waive early termination fees and/or penalties applicable to the Tenant if Tenant decides to relocate its operation into a stand-alone building or a "Quick Start Building" owned at the time of relocation by Landlord or any of its subsidiaries or related companies.
		
	5.02
	Events of default by Tenant and termination of agreement by Landlord.

Landlord may terminate the Lease Agreement without the need of a Cure Period due to: a) upon Rent Commencement Date, non-compliance by Tenant in respect to all obligations of the Free Trade Zone Regime, including having all permits and authorizations current, and if it is not a beneficiary of the Free Trade Zone Regime; provided the non-compliance of such obligations may economically, materially and adversely affect Landlord.  Otherwise the thirty calendar day Extended Cure Period established below shall apply; b) In case the due payment of Rent and Service Fee is not made within seven (7) days after receipt of notice from Landlord.  Tenant shall pay compensation as indicated in Section 5.01 above, without prejudice of further indemnities.  Tenant may inform Landlord of any reason(s) for delay(s) in payment, and Landlord reserves the right to accept or refuse such late payment in good faith.  In case the Landlord does not receive payment within the time set forth above, Landlord will be entitled to terminate the Lease Agreement with responsibility for Tenant, and Landlord will have the right to be compensated in accordance with Section 5.01 above 
Landlord may also terminate the Lease Agreement after the Cure Period, as defined below, due to other cause expressly authorized by the legislation in effect ("Events of Default").  Once the Landlord detects an Event of Default, it will communicate so in writing to the Tenant.
Except as otherwise established above, Tenant will have seven (7) calendar days ("Cure Period") subsequent to the receipt of the communication to remedy any of the following defaults, provided such defaults are Tenant's fault, and are not justified reasonably: a) Failure to comply with restrictions of use of the Premises as per the Lease Agreement and Condominium By-laws; b) Failure to comply with the responsibility for damages to the Premises and Condominium by Tenant (including its employees, officers and/or agents, or by third parties or clients that visit or use the Premises); c) Failure to comply with obtainment and maintenance of all construction and operation permits in order, c) Material non- compliance with all applicable laws and regulations, and with the Other Commitments in Section 3.13 above.  Non material events of default shall be cured according to the next paragraph.

-20-

Tenant will have thirty (30) calendar days ("Extended Cure Period") if it fails to comply with any other obligations provided in the Lease Agreement, not specifically referred to in the foregoing paragraph, subsequent to the receipt of a communication to remedy the situation causing such non-compliance.
If the Tenant does not amend the situation that originated the communication during the Extended Cure Period or the Cure Period provided, or gives a satisfactory response to Landlord, at least requesting an extension of the Extended Cure Period or the Cure Period, or if such response is unreasonable, Landlord will be entitled to terminate the Lease Agreement with responsibility for Tenant, and Landlord will have the right to be compensated in accordance with Section 5.01 above.
		
	5.03
	Events of default by Landlord and termination in advance on the part of the Tenant

Non-compliance on the part of Landlord with the obligations established in the Lease Agreement or any other cause expressly authorized by the legislation in effect ("Events of Default") will be considered a breach.  Once the Tenant detects an Event of Default, it will communicate so in writing to Landlord.  Landlord will have thirty (30) calendar days ("Cure Period"), subsequent to the receipt of a communication to remedy the situation causing such non-compliance.
If the Event of Default makes the Premises materially unusable to Tenant for its intended purpose, Landlord shall have seven (7) calendar days ("a Cure Period") subsequent to the receipt of the communication to remedy the Event of Default.  If the Event of Default is not corrected after the Cure Period, or gives a satisfactory response to Tenant, at least requesting an extension of the Cure Period, or if such response is unreasonable, Tenant will be entitled to take all actions established in the Leases and Subleases Law of Costa Rica (Ley General de Arrendamientos Urbanos y Suburbanos), including the cure of such default itself at Landlord's expense, if applicable.  In that case, Landlord will reimburse Tenant for all costs and expenses so incurred by Tenant within thirty (30) calendar days after Tenant delivers to Landlord all invoices correspondent to such costs, unless both parties agree that payment is made by means of deduction of the total amount owed for such costs from next monthly rent payment thereafter due under this Lease, and if such payment is not enough, by deducting from the following months until the complete amount owed and its interest has been credited to the Tenant.  If Landlord does not agree with the amount charged by Tenant, it will be resolved as per Section 7.01 below 
Section Six. Final and Miscellaneous Provision 
		
	6.00
	Communications and Notices 

Any notice that the Parties are required to make in accordance with this Agreement, shall be made in writing by means of a personal delivery or any other written means, in which the remission and reception date, are irrefutably recorded, and sent to the following addresses and during office hours.  Notices shall be deemed delivered on reception date.

-21-

	
		
	a) to the Landlord:
	At the administrative offices of Carlos Wong, at the administrative offices of Coyol Free Zone, located in Coyol Free Zone administrative building.

	b) To the Tenant:
	To the attention of Luis Gutierrez at Tenant's Offices in Coyol Free Zone.

		
	6.01
	Governing Law and Dispute Resolution 

This Lease Agreement shall be interpreted and governed by the laws of the Republic of Costa Rica.
Any and all disputes, claims, differences, disputes or controversies arising out of or in relation to any aspect of this Lease Agreement, its business matter, performance, liquidation, interpretation, validity or any breach thereof, shall be resolved by the Ley de Proceso Monitorio Arrendaticio of Costa Rica.  All other matters related to this Lease Agreement shall be hereby irrevocably submitted to the jurisdiction of Costa Rican Courts.  Additionally, if the matter in dispute is not included in such law, parties shall resolve the issue by arbitration in accordance with the bylaws of the International Center for Conciliation and Arbitration of the Costa Rican-American Chamber of Commerce ("CICA"), arbitration shall take place in San Jose, Costa Rica at the International Center for Conciliation and Arbitration of the Costa Rican-American Chamber of Commerce ("CICA").  The parties hereby agree to submit voluntarily and unconditionally to its rules and aforementioned bylaws and claim knowledge thereof.  Any such arbitration shall be conducted in the Spanish language.  The arbitration tribunal shall be composed of three arbitrators; each party shall appoint one arbitrator, and these two arbitrators shall appoint a third arbitrator who will act as president of the arbitration tribunal.  The foregoing agreement to arbitrate is specifically enforceable and the award rendered by the Arbitrators is final and binding on the parties to this Agreement and the judgment may be entered upon any arbitration award.  By virtue of the above, parties expressly waive the use of the jurisdiction of Costa Rican Courts, with the exception established above.
Any matters that cannot be subject to arbitration under Costa Rican Law shall be hereby irrevocably submitted to the jurisdiction of Costa Rican Courts.
		
	6.02
	Amendments to the Agreement 

Any agreed modifications to the present Agreement must be done in writing and signed by the Parties.  This clause shall be of special application for anything related with the lease price and its form of payment; therefore, no modification may be alleged, unless the previous procedure is followed.
		
	6.03
	Estimation 

The present Agreement is estimated for tax purposes in the sum of three million six hundred and sixty-five thousand two hundred and ninety five dollars with sixty cents (US$3,665,295.60) legal currency of the United States.
		
	6.04
	Recordation.

-22-

Subsequent to execution, any party may at its sole discretion and expense, register this Lease and all Exhibits thereto in the National Public Registry of Costa Rica.
		
	6.05
	Vested Rights 

The Tenant recognizes that this Agreement shall not create any goodwill, or right of use or other intangible right, by virtue of which the eventual increase in the commercial value of the real estate shall be recognized for its use or occupation, and that in case such rights ever arise in accordance with any applicable legal regulation or commercial practice, Tenant hereby assigns such right to the Landlord in the amount of one dollar, legal currency of the United States of America.  The Tenant recognizes that this provision is essential on the part of the Landlord to enter into the present Agreement.
		
	6.06
	Headings 

The titles used as headings for each clause and chapter of this Agreement are introduced to ease it's reading and shall not be considered as part of the text thereof, to interpret its contents.
		
	6.07
	Incorporation of Exhibits 

The Exhibits identified in this Agreement are incorporated herein by reference and made a part hereof.
		
	6.08
	Survival

All indemnities contained in any section of this Agreement shall survive the expiration or other termination of this Agreement with respect to acts or events occurring or alleged to occur during the term of this Agreement and are expressly made for the benefit of, and shall be enforceable by any or all of the indemnified Parties.
		
	6.09
	Severability 

If any of the provisions of this Lease shall contravene or be invalid under the laws of the country, province, municipal, state or jurisdiction where it is applied, such contravention or invalidity shall not invalidate the Lease or any other portions thereof and the remainder of this Lease or the application thereof to other persons or circumstances shall not be affected thereby.
		
	6.10
	Counterparts 

This Agreement may be executed in counterparts, each of which when executed and delivered shall be deemed an original.  Such counterparts shall together (as well as separately) constitute one and the same instrument.
		
	6.11
	Confidentiality 

Landlord and Tenant each agree to respect and preserve the confidentiality of all "Confidential Information" received from the other.  "Confidential Information" means (i) the existence and contents of this Lease Agreement, and (ii) any information of a proprietary or 

-23-

confidential nature relating to the business or the assets of Tenant or Landlord, or any of their respective affiliates or related companies that is not public information known by either of the parties prior to the date of the Letter of intent or this Lease.  Neither party will disclose Confidential Information of the other party except disclosure to its (or its affiliates) respective directors, principals, officers, employees, advisors, agents, lenders and consultants to the extent necessary to perform its obligations under this Lease Agreement or as otherwise required by law, by court order, or by obligations imposed on the disclosing party pursuant to any listing agreement with any national securities exchange.
		
	6.12
	Arbitration 

Any and all disputes, claims, differences, disputes or controversies arising out of or in relation to any aspect of this Agreement, its business matter, performance, liquidation, interpretation, validity or any breach thereof, shall be resolved by arbitration in accordance with the bylaws of the International Center for Conciliation and Arbitration of the Costa Rican-American Chamber of Commerce ("CICA").  The parties hereby agree to submit voluntarily and unconditionally to its rules and bylaws and claim knowledge thereof.  Disputes shall be resolved by an Arbitration Tribunal composed of three arbitrators; Each party shall appoint one arbitrator, and these two arbitrators shall appoint a third arbitrator who will act as president of the Arbitration Tribunal.  The Parties hereby agree, that they cannot assign their rights and obligations under this Contract totally or partially without mutual approval however Tenant may assign its rights and delegate its duties hereunder to any entity which is controlled by or under the common control of Tenant, its ultimate parent or any of its affiliates and Landlord may assign its right to compensation under this agreement, for financing purposes.  The Guarantee shall survive any such assignment, and remain valid.

-24-

IN WITNESS WHEREOF, the Parties hereto have executed this Agreement as of the date first above written.

	
			
	/s/ Juan José Chacón

	Name: Juan José Chacón

	 
	 

	Date and Place: 
	August 15, 2015, San Jose, Costa Rica

	 
	 
	 

	By: Establishment Labs S.A. 

	Tenant
	 
	 

	
					
	/s/ Álvaro Carballo Pinto 
	 
	/s/ André Garnier Kruse

	Álvaro Carballo Pinto 
	 
	André Garnier Kruse

	 
	 
	 
	 
	 

	Date and Place: 
	 
	 
	Date and Place: 
	 

	 
	 
	 
	 
	 

	 
	 
	 
	 
	 

	By: Zona Franca Coyol S. A. 

	Landlord

LIST OF EXHIBITS
	
			
	Exhibit One: 
	 
	Certifications of Legal Representation.

	 
	 
	 

	Exhibit Two: 
	 
	Location at the Master Plan of Premises and Layout.

	 
	 
	 

	Exhibit Three: 
	 
	Cold Shell Building Description 

	 
	 
	 

	Exhibit Four: 
	 
	a) Condominium By-laws and b) Park Regulations.

	 
	 
	 

	Exhibit Five: 
	 
	Usage regulation of the Sewage Treatment Plant.

	 
	 
	 

	Exhibit Six: 
	 
	Additional Monthly Service Fee.

	 
	 
	 

	Exhibit Seven: 
	 
	Wire Transfer Information.

	 
	 
	 

	Exhibit Eight: 
	 
	LOI dated February 23rd , 2015 

	 
	 
	 

	Exhibit Nine: 
	 
	Letter of Credit 

Exhibit 1
Certificates of Legal Representation

LEXCOUNSEL
NÚMERO CIENTO NOVENTA Y TRES - DOS MIL QUINCE. JULIO ENRIQUE ZELAYA RODRIGUEZ, NOTARIO PÚBLICO DE SAN JOSE CON OFICINA EN ESCAZÚ, EDIFICIO TERRAFORTE, CUARTO PISO, BUFETE LEX COUNSEL CERTIFICA: A solicitud de ZONA FRANCA COYOL, S.A., con cédula de persona jurídica número tres- ciento uno- cuatrocientos veinte mil quinientos doce, que de conformidad con el Sistema Digitalizado del Registro de Personas Jurídicas del Registro Público, bajo la cédula de persona jurídica número tres- ciento uno- cuatrocientos veinte mil quinientos doce, que: a) ZONA FRANCA COYOL, S.A., se encuentra debidamente constituida, inscrita y vigente; b) los señores ALVARO CARBALLO PINTO, mayor, casado, empresario, vecino de San José, con cédula de identidad número uno- quinientos treinta y seis- seiscientos cincuenta y cinco, ANDRE GARNIER KRUSE, mayor, casado, empresario, vecino Alajuela, con cédula de identidad número uno-cuatrocientos dieciséis- mil trescientos cuarenta y uno y JORGE MONGE AGÜERO, mayor, casado, empresario, veino de San José, con cédula de identidad número uno- cuatrocientos trece- mil trescientos cuarenta y uno, son respectivamente PRESIDENTE, SECRETARIO y TESORERO de la Junta Directiva de la sociedad, a quienes .les corresponde la representación judicial y extrajudicial de la sociedad con facultades de apoderado generalísimo sin limite de suma de conformidad con el artículo mil doscientos cincuenta y tres del Código Civil, debiendo actuar conjuntamente al menos dos de ellos. Podrán, actuando de la forma dicha, nombrar apoderados con la designación y atribuciones que harán constar en el propio acto del nombramiento, sin por ello perder sus facultades originales. - Expido la presente certificación en lo conducente, no hay asientos posteriores que modifiquen, alteren, condicionen o restrinjan, ni desvirtúe lo aquí certificado, al tenor del artículo ciento diez del Código Notarial.- ES CONFORME. Se agregan y cancelan las especies fiscales de ley. Se expide en San José, a las quince horas diez minutos del diez de agosto del año dos mil quince.

REPUBLICA DE COSTA RICA 
REGISTRO NACIONAL 
CERTIFICACION LITERAL 
NUMERO DE CERTIFICACION: RNPDIGITAL-4035876-2015 
PERSONA JURIDICA: 3-101-366337
DATOS GENERALES
RAZON SOCIAL O DENOMINACION: ESTABLISHMENT LABS SOCIEDAD ANONIMA
ESTADO ACTUAL: INSCRITA
DOCUMENTO ORIGEN: TOMO: 531 ASIENTO: 38 FECHA INSCRIPCION /TRASLADO: 31/03/2004
DOMICILIO: ALAJUELA-ALAJUELA LA GARITA, ZONA FRANCA COYOL, EDIFICIO B QUINCE, OFICINAS DE ESTABLISHMENT LABS.
OBJETO/FINES (SINTESIS): COMERCIO, EXPORTACION, IMPORTACION, GANADERIA, VENDER, HIPOTECAR, DISPONER DE BIENES, LOS BIENES RAICES, FIDEICOMISOS, RENDIR TODA CLASE DE FIANZAS Y GARANTIAS, RECIBIR DONACIONES, LEGADOS
PLAZO DE LA ENTIDAD JURIDICA: INICIO: 18/01/2004 VENCIMIENTO: 18/01/2104
PRORROGAS EN EL PLAZO DE LA ENTIDAD JURIDICA: NO INDICA
NUMERO LEGALIZACION: 4061010315591
FECHA LEGALIZACION:04/07/2014
CONFORMACION DEL CAPITAL O PATRIMONIO
FECHA DE INSCRIPCION: 25/04/2014 TIPO DE CAPITAL: SUSCRITO Y PAGADO TIPO DE MONEDA: DOLARES
CLASE DE ACCION O TITULO: ACCIONES COMUNES Y NOMINATIVAS
CANTIDAD TITULOS: 1 MONTO: 10,268,857.00 TOTAL: 10,268,857.00
NO EXISTEN MAS REGISTROS DE CAPITAL/PATRIMONIO PARA LA PERSONA JURIDICA
ADMINISTRACION
PLAZO DE DIRECTORES Y/0 PRORROGAS: LA JUNTA DIRECTIVA, EL GERENTE GENERAL Y EL FISCAL SON NOMBRADOS POR TRES
AÑOS
LA JUNTA DIRECTIVA NO TIENE FACULTAD PARA OTORGAR PODERES
REPRESENTACION
LA REPRESENTACION JUDICIAL Y EXTRAJUDICIAL DE LA SOCIEDAD CON FACULTADES DE APODERADO GENERALISIMO SIN LIMITE DE SUMA PARA TODOS LOS NEGOCIOS DE LA SOCIEDAD DE CONFORMIDAD CON EL ARTICULO 1253 DEL CODIGO CIVIL SERA EJERCIDA POR DOS MIEMBROS DE LA JUNTA DIRECTIVA SIEMPRE QUE ACTUEN EN CUALQUIER DE LAS SIGUIENTES COMBINACIONES: A) EL PRESIDENTE CONJUNTAMENTE CON EL SECRETARIO, O CON EL TESORERO, O CON EL VOCAL UNO; B) EL VICEPRESIDENTE CONJUNTAMENTE CON EL SECRETARIO, O CON EL TESORERO, O CON EL VOCAL UNO; C) EL VOCAL DOS CONJUNTAMENTE CON EL SECRETARIO, O CON EL TESORERO, O CON EL VOCAL UNO. EL PRESIDENTE, VICEPRESIDENTE, SECRETARIO Y TESORERO DE LA JUNTA DIRECTIVA, PODRAN ACTUAR INDIVIDUALMENTE CON FACULTADES DE APODERADOS LIMITADOS A LA SUMA DE QUINCE MIL DOLARES MONEDA DE CURSO LEGAL DE LOS ESTADOS UNIDOS DE AMERICA O SU EQUIVALENTE EN MONEDA NACIONAL; SIN EMBARGO, NO PODRAN REALIZAR NINGUNA DE LAS ACCIONES RESERVADAS A LA JUNTA DIRECTIVA, SIN LA AUTORIZACION DE ESTA, DE ACUERDO CON LO ESTITUPULADO EN ESTOS ESTATUTOS. ADICIONALMENTE, LA COMPAÑIA TENDRA UN GERENTE GENERAL QUIEN PODRA SER SOCIO O NO Y QUIEN PODRA SER A SU VEZ, ALGUNO DE LOS MIEMBROS DE LA JUNTA DIRECTIVA A EXCEPCION DEL PRESIDENTE. EL GERENTE GENERAL EJERERA ASI MISMO LA REPRESENTACION DE LA SOCIEDAD Y CON TAL FIN TENDRA PODER GENERAL LIMITADO A LA SUMA DE QUINIENTOS MIL DOLARES, MONEDA DE CURSO LEGAL DE LOS ESTADOS UNIDOS DE AMERICA, DE CONFORMIDAD CON EL ARTICULO 1255 DEL CODIGO CIVIL. ACTUANDO DE MANERA INDICADA, TAMBIEN PODRAN CONFERIR U OTORGAR PODERES DE TODA CLASE A CUALQUIER PERSONA CON LAS FACULTADES, LIMITACIONES Y PLAZOS QUE CONSIDEREN CONVENIENTES, SIN EXCEDER SUS FACULTADES. LOS PODERES DE LOS REPRESENTANTES LEGALES DE LA COMPAÑIA NUNCA PODRAN SOBREPASAR LA AUTORIDAD Y PODERES DE LA JUNTA DIRECTIVA O DE LA ASAMBLEA GENERAL DE ACCIONISTAS, COMO SE ESTABLECE EN EL PACTO SOCIAL. LOS PODERES DE LOS REPRESENTANTES LEGALES NO LOS FACULTA PARA TOMAR ACCION ALGUNA REFERENTE A ASUNTOS QUE REQUIEREAN AUTORIZACION DE LA ASAMBLEA GENERAL DE ACCIONISTAS O DE LA JUN TA DIRECTIVA.
NOMBRAMIENTOS
JUNTA DIRECTIVA
FECHA DE INSCRIPCION: 25/04/2014 CARGO: PRESIDENTE
OCUPADO POR: ROBERTO EDUARDO PONCE ROMAY PASAPORTE: 17973652 N
REPRESENTACION: REPRESENTACION JUDICIAL Y EXTRAJUDICIAL
VIGENCIA: INICIO: 22/10/2013 VENCIMIENTO: 22/10/2016
,ECHA DE INSCRIPCION: 25/04/2014 CARGO: TESORERO
OCUPADO POR: DIEGO FRANCISCO GOMEZ DUEÑAS CEDULA DE IDENTIDAD: 1-0822-0493
REPRESENTACION: REPRESENTACION JUDICIAL Y EXTRAJUDICIAL
VIGENCIA: INICIO: 22/10/2013 VENCIMIENTO: 22/10/2016
FECHA DE INSCRIPCION: 25/04/2014 CARGO: SECRETARIO

Exhibit 2
Location at the Master Plan of Premises and Layout.

Exhibit 3
Cold Shell Building Description

MULTITENANT LOT 26 CONSTRUCTION DESCRIPTION 
ESTABLISHMENT LABS SHELL BUILDING SCOPE OF WORK
		
	General description:
	The project consists of a cold shell manufacturing building. It includes exterior works such as a parking lot, loading docks, gardens, and landscaping. All designs comply with Costa Rican construction codes; soil surveys are available for tenant’s review. This facility will be part of a Multitenant Building.

		
	Construction areas:
	Cold Shell Manufacturing Area: 2,600 square meters (27,986 square feet).

Parking and loading areas: An exterior parking lot for eighteen vehicles and one loading dock, complying accessibility requirements as per local codes. Loading area with dock for one container.
Manufacturing Area:    
		
	Number of floors:
	One floor (ground level).

		
	Structure:
	Made of either pre-cast reinforced concrete or metal columns, beams, girders and gutters, with a 32 meter maximum span between columns. Minimum clearance up to the lowest part of the roof beams is 6.5 meters. Design complies with Costa Rican Seismic Code, Revision 2010 (latest version).

This structure is not intended to support any additional overloads, other than those required by Costa Rican Seismic Code. Any overload to be applied to this structure must be submitted to Coyol Free Zone’s structural engineer for approval (see Upgrades to Building Shell section below).
		
	Foundations:
	Built with reinforced concrete.

		
	Gutters:
	Built with either pre-cast reinforced concrete as part of the building structure or 24 ga. galvanized/enameled steel.

		
	Enclosures:
	Built with a combination of concrete/masonry, concrete panels, glass windows and drywall (e.g. Durock, Dens glass, etc.).

The South facade, where a removable wall to allow future expansion is required, will be made of two layers of enameled steel with at least 1.5” insulation (see Upgrades to Building Shell section below). If required, this wall will have a secondary metal structure.
Penetrations on perimeter walls and roof must be coordinated between tenant and Coyol, so that they do not affect building weather seal and/or aesthetic.
		
	Paint:
	The manufacturing building will be fully painted with one basecoat and one finished coat on the outside only; no paint will be applied to the inside. Paint will be an acrylic type by Sherwin Williams, “Weather Perfect” or similar. Colors will be chosen by Coyol Free Zone.

		
	Glass:
	Class B floated glass with color on aluminum frames with anodized paint. Thickness complies with local regulations; in the two storey lobby safety film will be applied (see Upgrades to Building Shell section below).

		
	Doors:
	Loading docks will have 2.45 meters (horizontal) by 2.75 meters (vertical) metal overhead door, to be operated manually (upgradeable to motor + seals + levelers, as leasehold improvements). There will be access metal doors for pedestrians without anti-panic hardware, distributed according to Costa Rican regulations (see Upgrades to Building Shell section below).

		
	Roof cover:
	Prefabricated panel system consisting of two enameled steel layers with 2” thick foam insulation in the middle. Roof cover will be waterproof. If required due to lack of rain at the moment of delivery, testing will be done with water pump and hose simulating a maximum precipitation of 144.4 mm/hr.

Storm water downspouts will be made of Polyvinyl chloride (PVC) SDR-26 and they will be visible in manufacturing area.
		
	Flooring:
	Manufacturing floor consists of a 0.15 meter thick steel reinforced concrete slab. This floor is delivered with the following parameters: Floor Flatness of 35 and Floor Leveling of 25, according to ACI 302 standard. The manufacturing floor is designed to support a distributed load of 2 Ton/m2. Elastomeric fills for construction and control joints or between slab on grade and building walls is not included. No concrete sealant is included. No vapor barrier is included.

		
	Interior Finishes;
	No interior finishes are included.

Exterior Works:
		
	Parking:
	Eighteen parking spaces and one loading dock. Pavement to be either asphalt, concrete or concrete pavers, located at the exterior of the building.

		
	Loading docks:
	Loading docks for 1 container is provided,

		
	Sidewalks:
	Sidewalks provide access to parking areas, main and employees’ entrances.

		
	Canopies:
	Eaves will be provided for:

		
	•
	Lobby entrance

		
	•
	Pedestrian doors

		
	•
	Loading dock

		
	Setbacks:
	Defined according to Condominium Bylaw. Specifically:

		
	•
	Any utility room or mezzanine adjacent to the building must not be visible from the street in front of the main facade.

		
	•
	Any utility room or mezzanine adjacent to the building shall be lower in height than the gutter of the main building and must have an 8.55m lateral and rear setback from the property line.

		
	•
	Any utility room or mezzanine built separate from the main building and lower than 5.00m over the average street level in front of the building facade (730 m.a.s.I.) shall have a 5.00m lateral and rear setback, setback will increase one meter for each meter of additional height.

		
	•
	No mechanical or power equipment shall be considered a construction therefore it will not generate setbacks, and shall not be exposed or showing on the wall surface of the subsidiary properties or future buildings.

		
	Landscaping:
	Garden and lawn surround the building.

		
	Systems:
	Full storm water connection (from roofs and exterior areas to Condominium’s general collector) capable of handling a peak intensity of 144.4 mm/hr, with a return period of 5 years and a concentration factor 12.39 minutes.

		
	•
	1 Potable water connection at ground level on the Park’s sidewalk in front of the building, from the closest point of Condominium’s network. Provided connection will have service pressure of 70 psi.

		
	•
	1 sewage connection at ground level on the Park’s sidewalk in front of the building, from Condominium’s collector. Provided connection will have 100 mm diameter.

		
	•
	Automatic Irrigation system connected to tenant’s water meter and electrical panel.

		
	•
	Exterior lighting for architectural accents around manufacturing building will have reflector type fixtures. Lighting at parking areas will be by means of either poles or bollard type fixtures. Light fixtures and bulbs will be for external use.

		
	•
	One 3-phase middle voltage connection will be provided at a switchgear located at the Park’s sidewalk close to the building, with the following specifications: underground load interrupting overcurrent protection in deadfront, compact construction switch equipment connections for a Max. Voltage of 38KV, 150 KV BIL, 600 continous amps, 12kA Asym momentary, 12 kA asym Close/Fault. The switch equipment includes: resettable, fuseless protection, single and 3-phase trip, wide variety of protection emulation curves including ground fault, removable tamper-resistant enclosures, minimal maintenance, multi-way switch configurations and cable entrance flexibility, complying with ICE requirements.

		
	•
	Conduits connecting to 10E’s telecommunications system from inside the building, cable is not included.

The Allowance does not include:
		
	•
	Telecommunication cables.

		
	•
	Automatic transfer switch, or backup generator.

		
	•
	Pad Mounted Transformers.

		
	•
	Additional internal windows.

		
	•
	Private bathrooms.

		
	•
	Special finishing for walls.

		
	•
	Closets, equipments or furnishings.

		
	•
	UPS or telecom equipments.

		
	•
	Alarms, close circuit TV, special security programs.

		
	•
	Neither electrical nor mechanical interior installations, other than those described as part of the scope for Manufacturing Area.

		
	•
	Raised floorings or special finishes on tiles or carpets.

		
	•
	Structured cable and systems (voice/data network).

		
	•
	Air compressor.

		
	•
	Telecom and data transmission network and equipment.

		
	•
	Precision A/C or dedicated A/C for computer rooms.

		
	•
	FM-200 or special fire systems, like sprinklers and smoke detectors.

		
	•
	Furniture or kitchen equipment.

		
	•
	Chemical storage area.

		
	•
	Ventilation systems.

		
	•
	Electrical room.

		
	•
	Mechanical room.

		
	•
	Canopies for parking areas.

		
	•
	Polyethylene vapor barrier under slab on grade.

		
	•
	UPS or telecom equipments.

		
	•
	Alarms, close circuit TV, special security programs.

		
	•
	Internal mechanical installations other than those indicated.

		
	•
	Raised or special floor finishes.

		
	•
	Air conditioning for manufacturing building.

		
	•
	Utility yard or equipment pads.

		
	•
	Interior finishes other than those specified in the scope of work,

		
	•
	Dock levelers, seals or any accessory not specified in the Manufacturing Area scope of work.

		
	•
	Interior windows for manufacturing building.

		
	•
	Bathrooms for manufacturing building.

		
	•
	Neither electrical nor mechanical installations inside manufacturing building.

		
	•
	Fire protection system (tank, pumps, cabinets, accessories, etc.).

		
	•
	Special finishing for walls or movable walls.

		
	•
	Closets, equipments or furnishings other than kitchenette.

		
	•
	Air conditioning for manufacturing building.

		
	•
	Interior finishes other than those specified in the scope of work

Exhibit 4
Condominium By-laws and Park Regulations.

CONDOMINIO COYOL
CONDOMINIUM AND ADMMSTRATION BYLAWS:
In compliance with Articles Thirty-Three and Thirty-Four of THE LAW, the Condominium and Administration Bylaws of HORIZONTAL INDUSTRIAL COMMERCIAL CONDOMINIUM WITH PRIMARY INDIVIDUALIZED SUBSIDIARY PROPERTIES LOTS (FFPI), hereinafter CONDONIINIO COY° L are constituted, which shall regulate the relations of the condominium owners:  DEFINITIONS. The following words will be understood, for all of the purposes of this Bylaws, according to their respective definitions, to whit: ADIVIINISTRATOR or THE ADMINISTRATION: The individual or corporation named to exercise the Administration of the Condominium according to the procedures described in this Bylaw, and with the faculties that these Bylaws grant; SHARED AREAS OR ELEMENTS: Shared elements should be understood as all those zones that are set aside for shared use and enjoyment, within which we can mention the following, without implying an exhaustive list: green areas, spaces set aside for pedestrian circulation, sidewalks, bus stops, streets, access ways, surveillance posts, electrical substations, electrical distribution system, water reservoirs, potable water systems, fire systems, waste water treatment plant, potable water wells and pump station, access gates, as well as those which are stipulated as such by Law, the building blueprints and the Condominium deed of constitution; RESTRICTED USE SHARED AREA: These will be those shared areas that the Condominium Joint Owners’ General Meeting shall determine, by a vote of two-thirds of the total value of the Condominium, which shall be used only by one or multiple specific joint owners as a result of their industrial or commercial operational needs within the Condominium, resulting from the location of the shared area or because of any circumstance which in the judgment of the Owners’ General Meeting justifies that the use and enjoyment of the shared area be restricted to one or several specific joint owners, either through a direct request made to the Meeting or because the Meeting so decides. MEETING or CONDOMINIUM, JOINT OWNERS MEETING: Shall have the definition that is established in the Ninth article of these Bylaws. OCCCUPANTS: the companies that are effectively in occupation or hold the subsidiary properties. They may be the Joint Owners, lessees or any other occupants or holders. THE CONDOMINIUM: The Horizontal Industrial Commercial Condominium with primary individualized subsidiary properties (FFPI) Coyol Free Zone. VALUE DETERMINATION: the value of each property (share) is defined by the share of land owned by the individual owner in regards to the sum of the totality of individual owner properties that compose the Condominio Coyol. INDEPENDENT CONDOMINIUM: That which shall be formed by subjecting each subsidiary property of Condominio Coyol to the Condominium Property System. The independent condominium bylaw will be subject to the stipulations of the Condominio Coyol Bylaw and will be subject to the rulings of the Administration imposed by the Administrator of the Condominio Coyol. CONDOMINIUM JOINT OWNERS: These are the individuals or companies, who/which reside in the Condominium or not, which hold property title over the subsidiary properties of the Condominium. In the case in which the subsidiary property is at the same time the parent property of an independent condominium, such condominium will be considered a joint owner of Condominio Coyol and shall participate in the Meetings and voting of Condominio Coyol under one single representation which shall have one single opinion and orientation to vote in regard to the matters that are heard in each Meeting. ORDINARY AND EXTRAORDINARY MAINTENANCE FEE: A proportional part of the general expenses that the joint owners are obligated to cancel and which shall be set according to the square meters of built area in each subsidiary property, that is, the developed private built area within the Condominium’s property coefficient in relation to the Condominium’s total area. There shall be no obligation to pay neither an ordinary nor an extraordinary maintenance fee for undeveloped private areas. EXECUTIVES: Administrators, legal representatives and corporate executives in general who are installed in the Condominium. SUBSIDIARY PROPERTY: Each one of the lots that make up the Condominium, duly identified by a Lot number, and which shall be subject to different stages of development, all of which constitute the private areas of the Condominium. SHARED EXPENSES: Shared expenses will be understood to be those which refer to the Administration and maintenance of the Condominium which the joint owners are obligated to contribute to in a manner which is proportional to the percentage of their private property with regard to the overall value of the Condominium, measured in accordance to the square meters built. Shared expenses are those which are established by Law, such as the collection of solid waste, security, shared area maintenance, road maintenance, as well as those expenses which are specified by the Condominium Meeting by recommendation of Administrator of the Condominium in compliance with its obligations. LAW: The Regulating Law of Condominium Property, Law 

Number seven thousand nine hundred thirty-three of November Twenty-Five, Nineteen Ninety-Nine, and its reforms. ADMINISTRATIVE STAFF: Individuals in general whc render personal services to the Occupants or to the Administrator thereof. PROPERTY OF THE CONDOMINIUM: This is understood to be all of the area described in the Deed of Constitution of the Condominium which subjects said area to the Condominium Property System, including all of the corresponding improvements and entitlements thereto. SERVICE PROVIDER: The third party or company whom the Administrator of the Condominium will hire to provide the general services that the joint owners pay through their maintenance fee as entitled in this By-Law. BYLAW: The current Condominium and Administration Bylaw of Condominio Coyol. BUILDING CODE: The compliance of the construction codes and regulations that currently apply in Costa Rica will be a responsibility of each joint owner and the Independent Condominium. The Administration  of the Condominium will supervise and inspect fulfillment of al general construction guidelines established in these Bylaws, the Building Regulations and the general standards of architecture, urbanism, construction, structure, esthetics and landscaping for the Condominium anc the Independent Condominium BUILDING REGULATIONS: Regulations to be delivered by the Meeting. AFFILIATED SUBSIDIARY: The subsidiary properties of the independent condominiums. WORKERS: Individuals in general who render personal service to the Occupants. VISITORS: These are people who visit the Condominium for any reason, either invited by the Administration or by the joint owners, lessees, occupants or holders, under any title, or those people who work doing repairs, maintenance, construction, cleaning, or who simply visit, or people looking for work, with the exception of the administrative personnel and executives and workers of the Occupants.
FIRST CHAPTER: SCOPE AND TERM
FIRST ARTICLE: General obligatory nature: This Condominium and Administration Bylaw is obligatory to all the joint owners, lessees, occupants or holders under any title derived from the property in condominium, as well as any visitors to whom it may apply. Also, it will be obligatory on the successors of those rights or people who are entitled thereto under any title, lessees or subleases, as well as anybody, either individual or corporation, who under private contract or court ruling should acquire the property, possession thereof, the use and enjoyment of any of the subsidiary properties resulting from the Condominium, which shall be governed by Law, as well as the terms and conditions of the Deed of Constitution of the Condominium. Condominio Coyol is planned in such manner that each one of its subsidiary properties may be constructed and subjected to different stages of development which shall be independent one from others, each of which subsidiary properties shall be capable of being converted into the parent property of an independent condominium, without thereby losing its nature as a subsidiary property to the Condominium, in other words, all of the stages of development will always be connected as part of a general whole which shall enjoy the same services and shared areas. Consequently, the Bylaw of each one of the independent condominiums which will be constituted by each of the subsidiary properties shall be in complete harmony and uniformity with this Condominium and Administration Bylaw, which shall be generally applied and abided by the Condominium, and its stipulations shall prevail in the case of discrepancy, omission or confusion, over the stipulations of the Condominium and Administration Bylaw of the independent condominiums that are constituted by each one of the subsidiary properties that make up the Condominium, since they, even if they become the parent properties of new independent condominiums, shall conserve their nature as subsidiary properties to Condominio Coyol.
SECOND ARTICLE: Irrevocability: Should there exist any reserved private contract subscribed between the persons indicated in the preceding article which in any manner modifies, alters, or revokes the legal system established by Law and this Bylaw; it shall be found null for all purposes and shall lack validity in regard to the Joint Owners of the Condominium and in regard to third parties, as well as any stipulation of the internal administration regulation of each one of the independent condominiums which may be constituted by the subsidiary properties of the Condominium which modify, alter, revoke the stipulations of this Bylaw, unless otherwise established in these Bylaws. Expressly excluded from this provision are the documents that are mentioned in the Twenty-Ninth and Thirty Third Article of this Bylaw, which are acknowledged as valid and binding on all the joint owners.

THIRD ARTICLE: Reforms: This Bylaw shall be duly approved and enter in effect from the moment in which the Condominium is registered in the Public Registry. Any reform to this Bylaw, as well as the emission of new text shall correspond solely and exclusively to the Joint Owners Meeting, by unanimous decision of all the Condominium owners, according to the provision of Article 27, Paragraph 5, of the Law. In accordance with the above, any reform or draft of a new Bylaw must be verified by public deed and registered in the Public Registry, if such procedure is possible.
SECOND CHAPTER. PRIVATE ASSETS AND SHARED ASSETS.
FOURTH ARTICLE: Private Assets: The Condominium consists of fifty four subsidiary properties which are described as land for the construction of office buildings, industrial or commercial units, and which make up the private area of the Condominium suitable for construction. Each one of the subsidiary properties has been identified by means of a lot number, as appears on the corresponding blueprint as well as in the deed of constitution. The joint owners acquire, together with the subsidiary or private assets, the right to use the shared elements and areas that are defined by Law and this Bylaw, as well as those entitlements and obligations which are acknowledged and imposed by this Bylaw. In such manner that each one of the joint owners may hold and derive from the entitlement that they may nave over the subsidiary property understood to be the private area, the right to enjoy all of those elements of the Condominium that are stipulated for shared use and are necessary for its existence and conservation.
FIFTH ARTICLE: Shared Assets: Shared assets will be understood to be civil infrastructure works, such as: vehicular access ways and on-site concrete or paved roads, sidewalks and gutters with their respective curbs, the storm-water system, sewer system, potable water system, electrical power distribution system and exterior lighting grid, telephone and fiber optic network, irrigation system of share areas, waste water treatment plant, green areas and parks, power and telecom control room, water wells pump & control room, surveillance and vehicular access control stations, and perimeter fence, as well as any other urban development required according to law in keeping with the type of industrial or commercial development to be executed in the Condominium, as well as those set forth in Article Ten of the Law. Likewise and under Article 27 of the Law, shared assets will be those which are qualified as such by the Condominium Joint Owners’ Meeting, even if they are not so by nature, or also those originated out of the necessity, security, health, access, ornamentation and conservation of the Condominium.
SIXTH ARTICLE: The relationship between private and shared assets: No joint owner may be limited in the rational use and enjoyment of shared things, nor may any person allege entitlement to greater use of those things because the percentage of ownership of a private area may exceed that of other joint owners in accordance with the provisions of Law. The rights of each joint owner in regard to shared things may not be pledged, encumbered, attached, or transferred to separate dominion, as they are inherent property rights of the subsidiary property and are consequently inseparable therefrom. The pecuniary liability of the joint owner in regard to shared assets shall be determined on the basis of the percentage of developed privately-owned area that the owner’s subsidiary property represents with regard to the overall area of the Condominium, and renouncement of the use and enjoyment of shared things, be it express or implied, shall not relieve the joint owner from responsibility in regard to the conservation and reconstruction of said assets, or even from the payment of maintenance fees, together with any obligation derived from the Condominium Property System, meaning that the joint owners’ liability in regard to shared assets are inalienable. Those assets for shared use and enjoyment may be subject to leasing, prior agreement of the Condominium Joint Owners Meeting by a vote which shall not represent less than two thirds of the total value of the Condominium.
SEVENTH ARTICLE: Use of shared assets: The owners are obligated to ensure the due use of the shared assets of the Condominium, as well as to notify the Administrator of any situation, fact or act which jeopardizes the security and conservation of those assets. Each joint owner, lessee, Occupant or holder, or any individual or corporation which occupies a subsidiary property, independently from the owner thereof, shall be responsible for damages. caused to shared things through fault or negligence, or by its tenants, employees, salespeople, or visitors, and they will be liable to cover the costs incurred for repairs, failing which the sanctions set forth herein 

will be applied. Also, all of the Joint Owners, lessees, Occupants and holders under any title shall abstain from all acts, even within their own property, which impede or lessen the efficiency of the operation or use of the shared areas.
EIGHTH ARTICLE: Improvements to shared assets and maintenance: Under Article 30 of the Law, the Administrator is responsible on behalf of the Condominium Joint Owners’ Meeting for the care and surveillance of the shared assets and services, the care and operation of the installations and general services, as well as of all of the conservation processes of the Condominium. Furthermore, the Condominium Joint Owners’ Meeting may set the corresponding guidelines for the Administrator to perform his/her duties, and particularly regarding the care of the shared assets. Improvements to the shared assets shall be approved in the Condominium Joint Owners’ Meeting according to Article 14 of the Law in the following manner: a:: Necessary improvements shall be approved by owner votes representing a simple majority of the value of the Condominium, and b) Usefu, improvements, by owner votes representing two thirds of the value of the Condominium. The Joint Owners, lessees, Occupants or holders, under any title, are obligated to permit and support the annoyance caused by maintenance work in shared and private areas, as well as conservation work and repairs. Consequently, the access and throughway of the people in charge of overseeing, directing and performing such work shall be allowed in all of the areas of the Condominium that are involved in mainL’enance. The Administrator, on his/her part, shall implement all pertinent measures to ensure that the maintenance work produces as little annoyance or damage as possible.
THIRD CHAPTER. GOVERNING AND ADMINISTRATION BODIES
NINTH ARTICLE: On the Condominium Owners’ General Meeting, meetings, convocation and quorum: The Condominium Joint Owners’ Meeting, is the. Supreme Body of the Condominium and therefore its governing body, and its decisions are binding on all the joint owners, lessees, occupants or holders, under any title, of the subsidiary properties or areas of the Condominium. The Meeting is formed by all the joint owners, either individuals or corporations, which hold property title over the subsidiary properties of the Condominium. The meetings of the Joint Owners Meeting must be held ordinarily according to law and this Bylaw at least one time per year during the month of January, and extraordinarily when so summoned by a number of owners who shall represent one third of the total value of the Condominium or by the Administrator in performance of his/her duties under Article 25 of the Law or when so stipulated during a preceding Meeting. Quorum to call order of the Meeting on the First Summon will be accounted by those joint owners representing a minimum of two thirds of the Weal value of the Condominium, and by any number of joint owners present for the Second Summon. All summons shall be issued in writing and with acknowledgment of receipt by any adult person in his/her right mind who may be working at the domicile of the Joint Owners which they notified to the Condominium Administrator for that purpose. In cases in which the subsidiary is also the parent of another condominium, summon notice must be delivered to the office of the administrator of the Independent Condominium. At the option of the Condominium Administrator, summons must be made by means of a publication in a national newspaper at least 30 calendar days in advance of the date on which the Meeting will be held, without considering the day of the publication or the date of the meeting when estimating said period. Summon notices must specify the agenda with specific: issues for consideration, as no miscellaneous matters will be allowed; the place, date and time set for the first and second summons. Failure to fulfill any of the above-stated requisites will result in the annulment of Meeting held. Once the Meeting has been summoned, those subsidiary properties which are also the parents of independent condominiums must hold their own joint owners Meeting in advance to bring a single position to be taken in regard to the issues submitted for consideration on the agenda in the summon of Condominio Coyol, as well as to appoint a representative to attend the Meeting and vote according to instructions. In that case, the Meeting of each individual subsidiary condominium will hear or resolve its own internal issues, which may not have been previously included or described in the summon notice of Condominio Coyol, though point number one of their own summon and the primary reason. .For the meeting shall be to appoint the representative and provide voting instructions for the Condorninio Coyol’s Meeting. The Condominium’s Meeting will be presided over by the Administrator, except that the duly constituted Meeting should agree otherwise by simple majority vote of the attendee owners.

TENTH ARTICLE: General Meeting competence and qualified votes: It is the competence of the Condominium Joint Owners’ Meeting to resolve matters of shared interest that do not fail within the powers and obligations which shall be specified below for the Administrator. The Ordinary Meeting shall hear the Administrator’s report and accounts, approve the budget of the following year and determine how to fund said budget. The following agreements are exclusive to the Condominium Joint Owners’ Meeting and require unaniirnous approval of all the owners: a) Those which modify the general destination of the condominium. b) Variations of the proportional areas of the subsidiary properties with relation to the total area of Condominium or the area of the shared assets. c) Renouncement of the condominium property system. d) The encumbrance or pledging of the totality of the Condominium. e) Modification of the deed of constitution or this Bylaw. fl Intentionally deleted. g) Intentionally deleted. h) Modification of the general guidelines of the Condominium’s architectural language and the construction quality standards established herein. Furthermore, approval by at least two thirds of the votes of the total value of the Condominium will be required: a) To acquire new shared assets or specify in any manner how they may be utilized, as well as to destine parts or sections of the Condominium as joint-owned property which are not so by nature or which are essential to the existence, security and conservation thereof. Also, to restrict shared use areas to one or several of the Condominium joint owners as defined in this Bylaw. c) To authorize shared things to be leased. d) To approve the total or partial reconstruction of the Condominium. e) To determine the amount of insurance coverage that must be taken out on the Condominium, beyond the coverage stipulated by law. f) To approve and modify the Building Regulations g) Variation of the specific destination of a subsidiary property. h) Variation of the destination of existing shared assets. Under Article 27 of the Law, when, in all of the preceding cases, a single owner represents less than fifty percent of the total value of the condominium, the remaining fifty percent of the votes will be required, met in Meeting to resolve the stated agreements. All other agreements, except the Administrator’s appointment, as well as removal o to hear his/her resignation and the determination the amount of remuneration for his/her services, will be resolved by simple majority of the attending votes of the Meeting, such as and without being limited to the amount of the Condominium’s maintenance fee which each owner must cover in proportion to the value of that owner’s subsidiary property, as well as the determination and authorization of extraordinary maintenance fees. The Meeting may delegate its powers provided that it is not against the law or this Bylaw. All vote counts during Joint Owners’ Meeting will be calculated on the basis of the private area (filial lots) in square meters, in other words, each subsidiary property vote will count and be added up according to the percentage of ownership with regard to the total area ( filial lots ) of the Condominium that is specified in the description of the registered subsidiary properties of the Condominium.
ELEVENTH ARTICLE: Representation in the Condominium Owners’ General Meetings: The joint owners may be represented in the Joint Owners’ Meetings by general or universal proxies, duly qualified by a notarized affidavit no older than five calendar days, or by a proxy granted to any person, owner or not, which the proxy holder must submit in original, duly authenticated by ar attorney. In those cases in which the subsidiary property is also the parent property of another independent condominium, it must be represented in the Joint Owners’ Meeting by a special holder duly appointed for that purpose by the Joint Owners’ Meeting of such independent condominium subsidiary property, who may be the Administrator of the Independent Condominium. The special power of attorney granted for these purposes must be legalized and the special holder must accredit such legalization by presenting the original affidavit of the deed of legalization of the agreement, which shall specify the matters that the special holder may vote on, and how the holder should vote, and which matters may be discussed by means of a brief description of the arguments. Also, in the case in which the same subsidiary property belongs to more than one owner, or if rights of real usufruct or simple possession have been constituted thereupon, both the co-owners as well as the real property title holders and bare property holder shall be represented by one single person in the General Meetings, producing one single vote for the subsidiary property according to the provisions of law in regard to the person who is entitled to vote or by a legitimate decision of the parties, in which case the respective proxy letter, authenticated by a lawyer, shall be submitted.
TWELFTH ARTICLE: The Condominium Book: Al General Meeting resolutions shall be consigned in a Condominium Meeting Book that will be kept by the Condominium for that purpose, which shall be duly legalized by the Condominium Properties Section of the Public Registry under Article 28 of the Law. The Meeting Minutes shall be signed by the President and Secretary of each Meeting. Also, the accounting books will be kept as 

needed for the order, control and reporting capability of the Condominium Administrator, which must also be dully legalized by such dependency, or by the General Directorate of Direct Taxation.
THIRTEENTH ARTICLE: On the Administrator, Appointment, fees, removal, resignation and substitution: The Condominium Administration shall be in charge of an Administrator, who may be an individual or corporation, a joint owner or not, who in regard to the Condominium and the shared assets shall have universal powers of attorney without limit of sum according to Article 1253 of the Civil Code. The Administrator will remain in the position for a period of five years beginning on the date cf appointment by the Condominium Joint Owners’ Meeting and may be reelected indefinitely for equal and consecutive periods, however he will continue in office until a new Administrator is named, even though the five year term has passed. In the case of electing a corporation, it will designate an individual who will execute the corresponding functions in its name and behalf. The appointment of the Administrator shall be made by a two thirds vote of the total value of the Condominium in the Condominium Joint Owners’ Meetirg summoned for that purpose, from among the candidates proposed by any joint owner, the Joint Owners’ Meeting, or the outgoing Administrator. The Administrator will earn a month ,y fee which will be set by the Meeting that elects him, which will be reviewed once a year. The Administrator who is appointed for the Condominium may be removed prior to the expiration of the term of appointment by a vote representing two thirds of the total value of the Condominium and for causes which may be discussed and resolved in the Meeting summoned for that purpose. The Administrator may resign at any time, due to which he shall summon and inform the Condominium Joint Owners’ Meeting at least sixty calendar days in advance of the date on which the resignation becomes effective, so that the Meeting may take the corresponding measures to it’s. substitution, and receive and approve the Administrator’s final administration report. The Condominium Joint Owners’ Meeting shall appoint a Commission, which the outgoing Administrator may be on, to find suitable candidates to manage the Condominium within a term of thirty calendar days beginning on the submission date of the Administrator’s resignation, and it shall submit a recommendation thereof to the following Joint Owners Meeting that shall be summoned by the outgoing Administrator for such purpose. The Joint Owners Meeting for this purpose shall be held during the last five business days of the thirty calendar day term given to the Commission to find candidates, which shall foresee the term of the summons, and the appointment of the substitute will be conducted so that him/she/it may start in office on the date the outgoing Administrator’s resignation shall be effective, at the expiration of the sixty calendar days stipulated hereinabove, term during which the Administrator shall function normally. The term between the appointment of the substitute Administrator and the date of effect of the Administrator’s resignation will be used by both to inform the substitute Administrator regarding everything related to the Condominium and the Administrator’s current duties, as well as the obligations and entitlements provided by that position. When the Meeting appoints a substitute Administrator or a new one at the expiration of the term, the outgoing Administrator shall turn all the Condominium’s Books, Accounting and Financial Statements, and all of the documentation, office equipment and accouterments that were specified for administration use, over to the new or substitute Administrator. The new or substitute Administrator will have the same faculties, obligations, responsibilities and entitlements established by this Bylaw and the Law once the appointment has been accepted. The substitution of the Administrator and the appointment of the new one resulting from the expiration of term will be immediately registered in the Pubic Registry on the date of effect of the new appointment.
FOURTEENTH ARTICLE: On the Faculties of the Administrator: Under Article Thirty of the Law, the faculties of the Administrator of the Condominium are: a) The care and surveillance of the shared assets and shared services, providing the Condominium with a team of security officers to guarantee the safety of the shared assets and the people within it, and to ensure compliance with the provisions on entry, stopover, and exit of people, vehicles and goods as established in the Bylaw. b) Attention to, maintenance and operation of the public or shared installations and services of the Condominium, among which are without limitation: the maintenance and conservation of green areas, streets and vehicular and pedestrian access roads, sidewalks, curbs and gutters, the main entrance, the shared parking areas of the Condominium, and shared service installations, as well as the maintenance of the public lighting service in the shared areas. The Administrator will authorize access into the Condominium of all government and local agencies, governing and regulatory bodies, basic utilities, general services previously hired by the Condominium from data communications and cable television companies; c) Everything to do with the Administration and conservation of the Condominium, with the exception of the 

maintenance of the private areas of the subsidiary properties that are occupied by joint owners, including their administrative, green and service areas. The maintenance of the shared areas, public and shared streets and access ways, as well as green zones, and external and shared gardening shall be the responsibility of Administration; d) The execution of the Condominium Joint Owners’ Meeting agreements; e) Prior empowerment by the respective Joint Owner, the Administrator may file for the eviction of any occupant, other than a property owner, who repeatedly violates the Law, this Bylaw or the Park’s Regulations, or who intends to operate out of the Free Zone system and regulations, as long as such special regime remains in force and the applicable Law and Condominium Bylaws are expressly modified in order to permit the coexistence in the Condominium of companies that are beneficiary of the Free Zone Regime, and companies that are not. In such case, the Bylaws must be modified unless such amendment to the Bylaws materially affects the financial situation of Zona Franca Coyol, S.A., or the current beneficiary of the Free Trade Zone Regime as Administrator of the Free Trade Zone Park according to Free Trade Zone Law. f) To demand compliance by the Joint Owners of their obligations under this Bylaw and the Law; to oversee the protection of their rights, impose fines, sanctions and lodge court actions resulting from breaches and on behalf of the Condominium, and to issue the respective notifications and processes to the joint owners with regard to the norms that regulate the Condominium, and to issue advices and evict joint owners accordingly and by means of the applicable mechanisms and procedures. g) The Administrator is authorized to constitute in favor of government institutions or public utilities companies, easements on the Common Areas of the Condominium, that shall be required for the procurement, installation, maintenance and operation of basic public services for the Joint Owners. Therefore, the Administrator can perform all actions and execute all documents necessary to constitute such easements. The creation of any easements of this nature, may not affect the rights which to date Hologic Surgical Products Costa Rica, S. A., has, in his capacity as lessee of the subsidiary properties of the Province of Alajuela, numbers sixty-eight thousand five hundred and fourteen-F-zero zero zero and sixty-eight thousand five hundred and fifteen-F-zero zero zero, nor its operation in Condominium. The Administrator will be have a SPECIAL POWER OF ATTORNEY (Poder Especialisimo) pursuant to article 1408 of the Civil Code of the Republic of Costa Rica, to negotiate and sign all documents, forms, deeds and grant or donation deeds, affidavits and contracts required to achieve development, procurement, construction and donation to the Costa Rican Institute of Electricity, of the electricity distribution infrastructure and of telecommunications facilities and networks, for al: stages of development identified as Coycl Free Zone, located in the Condominium, and shall ensure the Instituto Costarricense de Electricidad„ and its representatives, the unrestricted right of way in the. Condominium for the construction, inspection, installation, maintenance and operation of infrastructure donated, or to be donated. FIFTEENTH ARTICLE: On the Obligations of the Administrator: It shall be the obligation of the Administrator: a) To render an annual report on Administration operations and results to the Condominium’s General Ordinary Meeting which is held in July of each year, and in each Meeting as requested by any joint owner or by the Condominium Joint Owners’ Meeting. b) To submit the projected Annual Administration Budget and Financial Statements related to the results of the Administrator’s performance, supported by accounting books which may be audited independently at the request of the Condominium Joint Owners’ Meeting by simple majority of attending votes and by an auditor appoint& thereby. c) To resolve conflicts that arise betweer joint owners related to the use and enjoyment of the shared assets of the Condominium. d) To collect maintenance fees and establish and maintain a legaI reserve fund, as well as collect fines, impose terms for the correction of breaches of this Bylaw and the Building Regulations, to take action according tc pertinent court rulings, to issue advices and execute evictions of joint owners. e) To oversee that the tranquility and order that must prevail in the Condominium are not disrupted in any manner, and to adopt any necessary corrective measures to correct such situations. f) To submit and make. available Condominium information to joint owners, upon request. g) To certify the outstanding debt of owners under title of ordinary and extraordinary maintenance fees, interest and fines,. requested by any Joint Owner or the Condominium joint Owners’ Meeting. h) Intentionally deleted. i) To execute all of the processes entrusted by the Condominium Joint Owners’ Meeting or imposed by Law or this Bylaw. j) The Administrator shall employ the care of a good parent in the fulfillment of himlherfits duties and will be only be liable for failings, faults, or negligence in attending and managing administration. The Administrator will not be liable for losses, damage and injury caused by actions taken or omitted under specific provisions of the Condominium Joint Owners’ Meeting, the Law or this Bylaw, or resulting from individual instructions given by Joint Owners, as may be. The Administrator will be liable for losses imputable thereto as a result of him/her/its Administration, fraud, tortuous, failings, faults or negligence, and because of acts performed other than as ordered by the Condominium Joint Owners’ Meeting, the Law or this 

Bylaw, which shall be paid by the administrator from him/her/its own pocket and such shall be reflected in the statement of earnings of the Administrator’s term of Administration; k) Only during the term in which the Lease Agreement referenced in Article 33 below is still in effect, it will be an obligation of the Administrator to give written notice to Cytyc Surgical Products Costa Rica, S.A., to the address indicated in such Lease Agreement of any Condominium Joint Owners’ Meeting that will be held in order to change or modify the Condominium Bylaws. Such notice shall be given to Cytyc Surgical Products Costa Rica, S.A. at least 30 calendar days in advance to the celebration of the Condominium Joint Owners’ Meeting and shall include a clear indication of the changes proposed. The Administrator will have no further responsibility other than delivery the notification as established hereto. I) To ensure compliance of the Building Regulations, for which he may hire a consultant who will be civil engineer or an architect duly collegiate in Costa Rica. The Administrator shall keep a Minute Book of Meetings on Constructions, duly identified and approved by the Joint Owner’s Meeting, which shall contain any subject addressed, its background, the Administrator’s considerations in rela.:ion to constructions and the vote and final decision in each case. Minutes shall be taken by those who appoint the Administrator, and shall be signed by it. The Administrator may also maintain a record numbered independently of each subject matter, with all documents related to the case. The Book of Minutes of Meetings on Construction and records of each case shall be in custody of the Administrator and will always remain in it’s offices, except when in use Administrator advisers and will be open custody papers by the Joint Owners or those persons expressly authorized by them in writing.
SEVENTEENTH ARTICLE: Faculties of the Administrator regarding Administration: The Administrator will have the following attributions regarding constructions, as well as all those assigned by the Building Regulations: a) To develop and interpret the architectural, construction, esthetic, urban and landscaping guidelines that are established in the Public Deed of Constitution of the Condominium, in the approved Plans and Blueprints of the Condominium approved by the corresponding authorities, and in the Bylaw of the Condominium, in such manner that all of their specifications become an application, extension or logical consequence of such specifications, developing them and facilitating their application. b) To supervise and inspect, as required by the Condominium and its Joint Owners, the approved Plans and Blueprints of specific construction or improvement of a common area work. c) To fulfill all the functions and tasks that the Condominium Joint Owners’ Meeting assigns thereto. d) To ensure that all construction in the Condominium, either in its shared or private areas, meets the applicable norms and regulations of all public regulatory agencies, plans and the general design of Condominio Coyol, its Deed of Constitution and Bylaw and Building Regulations. f) To impose the fines and sanctions established in this Bylaw and reflected by the Building Regulations to the Joint Owners who violate its provisions, in which the Administrator will fully collaborate. g) To recommend to the Meeting the establishment or modification of said fines and sanctions, or other necessary norms in the Bylaw of the Condominium. h) To recommend to the Meeting to lodge legal action against Joint Owners who violate the construction, architectural and urban codes of the Condominium. i) To propose modifications or improvements to the Condominium’s shared areas. k) To name at discretion up to two professional advisors to attend to each issue that is put before it, and to set reasonable fees for the advisory services rendered thereby to resolve a matter of the Administrator’s competence. The fees of such advisors will be paid by the applicant Joint Owner, or by the one affected by the matter put before the Committee or by the Joint Owner who is affected by the Administrator’s resolution, as is set forth and established in the Building Regulations. The Administrator’s advisors will be selected according to criteria of absolute reasonability and will be hired by the Administrator’s to issue suitable professional criteria to solve each issue. I) To modify the specifications of the architectural language of the Condominium and the quality standards of the construction established by the Building Regulations and the Administrator, provided that they do not contradict the stipulations of this Bylaw.
EIGHTEENTH ARTICLE: Building Approval Procedure: Any construction in the subsidiary properties which the joint owners, lessees, occupants or holders under any title may wish to execute in the exterior of the buildings, including without limitation, building additions, façade modifications, color modifications, electrical installations and mechanical additions, must be approved by the Administrator of Condominio Coyol, that will not be unreasonable withheld. For this, they will submit a preliminary proposal or building plan to the Administrator which shall include all of the general relevant information, such as a construction specifications, location on the subsidiary property, connection with the public utility installations of the Condominium, and all other information that the Building Regulations will deem necessary. The Administrator may make suggestions and propose 

changes prior to the approval of the plans, and it will have ten business days counted as of the day following that on which the complete information of the projected construction is submitted. Approval of the preliminary project and plans by the Administrator must be obtained before the filial property owner processes the building permits before the public regulatory agencies. When the building plans are approved by the Administrator and by the public regulatory agencies, the Building Administrator will reserve a set of plans for verification and supervision of the construction and it will have unrestricted access thereto until completion, and regarding which it may request immediate changes, when construction does not coincide with what was previously approved. No construction may begin without having obtained and provided to the Administrator a copy of all construction blueprints duly approved by the corresponding entities.
NINETEENTH ARTICLE: Sanctions: Those joint owners who violate the stipulations and conditions of the Bylaw regarded to construction, the Building regulations and/or the guidelines established by the Administrator, will be subject to pay a fine equivalent to TWO THOUSAND DOLLARS of the United States of America per calendar day from the moment of initiation of construction without the prior authorization of the Administrator until such authorization is given. This fine will specifically apply to the cases set forth in this clause and shall exclude the application of the fine stipulated ir paragraph g) of the 23 Article of this Bylaw, notwithstanding that the procedure to charge such fine in the case of the default of payment in good faith of the joint owner, and its purpose, may be identical to the one set forth in the stated 23 Article. If the Administrator’s suggested changes are not implemented by the given joint owner ir his/her/its construction, and if the Administrator considers them necessary to guarantee the harmony and balance of the structure, systems anc general functions of the Condominium and the other joint owners, and that they are required ir defense of the common welfare, the Administrator may elevate to the knowledge of the Meeting, the he proposed construction, the changes suggested and the approval of the construction for the Condominium, and the joint owner will equally be liable to pay the fine established above to the Condominium if construction is initiated without the prior authorization of the Meeting, which must be given by a two thirds vote of the total value of the Condominium.
FOURTH CHAPTER: FINANCIAL PROVISIONS OF THE CONDOMINIUM:
TWENTIETH ARTICLE: The Condominium Bank Account: All of the funds that the Administrator receives and manages under title of maintenance fees according to the annual budget, as well as any other funds or amounts of money received by the Administrator in payment of the Condominium expenses, shall be deposited in a bank account which shall be opened by the Meeting in the name of the Condominium for that purpose, in which the Administrator will be authorized to sign checks, make withdrawals and deposit funds, and to execute any other usual bank account operation, except closing the bank account or opening others, which will require a decision by a simple majority of attending votes in the General Meeting. The persons who are expressly authorized by the Condominium Joint Owners’ Meeting to do so, may also sign on the bank account.
TWENTY-FIRST ARTICLE: Legal Reserve Fund: The Condominium annual expense budgets will include the formation and maintenance of a Legal Reserve Fund formed by annually withholding five percent of the cash income, up to twenty percent of the annual budget. The legal reserve fund will be specifically for the resolution of the Condominium’s extraordinary conservation, maintenance and restructuring needs, or to cover any delay in the collection of maintenance fees from permanent occupants, which will be dully supported by the Administrator. When the fund decreases to below the percentage stipulated herein, a surcharge will be imposed, the amount and form of which will be agreed by the Condominium Joint Owners’ Meeting, until the agreed amount is reached, in such manner that the Legal Reserve Fund remains at twenty percent of the annual budget of the Condominium.
TWENTY-SECOND ARTICLE: Maintenance Fees: a) Ordinary maintenance fees: The joint owners of the different subsidiary properties of the Condominium are obligated to contribute an ordinary maintenance fee which shall be set according to the square meters of the constructed private area of each subsidiary property, i.e., the constructed private area within the percentage of ownership compared to the total area of the Condominium, to cover: a.i) Maintenance fees, the modification and repair of the shared assets of the Condominium. a.ii) Insurance premium payments for the infrastructure civil works in the shared areas of the Condominium. a.iii) Tax, rate and 

fiscal or municipal contribution payments levied against the Condominium, the shared areas and fixtures thereof. a.iv) Administrative, security, and institutional publicity expenses, in equal proportion. a.v) The fee set for the Administrator. a.vi) Expenses under title of professional services contracted by the Condominium be they legal, accounting, auditing, engineering, topographic and any otier professional service which may need to be contracted to cover the general needs of all the Joint Owners of the Condominium. a.vii) Lastly, the ordinary maintenance fee will cover trash collection of the three point four cubic meter trash bins assigned to each joint owner. When collection requirements exceed the capacity of said bin, the service will be covered as an individual additional expense by each Joint Owner, who shall pay it independently and above the ordinary maintenance fee. Undeveloped private areas are not obligated to pay an ordinary maintenance fee. The ordinary maintenance fee will be set by the Condominium Joint Owners’ Meeting by a simple majority of attending joint owners in the Condominium Joint Owners’ Meeting as part of the approval of the Annual Budget submitted by the Administrator, and it will be collected and managed by the Administrator of the Condominium. Any delay in payment shall be subject to a late interest which shall be set by the Condominium Joint Owners’ Meeting for that purpose, which percentage shall prevail when the Condominium Joint Owners’ Meeting fails to expressly set a different one when it approves the ordinary maintenance fee each year. b) Extraordinary maintenance fees: In view that the shared areas of the Condominium are made up primarily of infrastructure and urban civil works such as: streets, sidewalks and vehicular and pedestrian access ways, curbs and their respective gutters, sewage, pluvial and sanitation systems, drinking water system, fire prevention system, power and exterior lighting network, telephone and cable television network, irrigation system, waste water treatment plant, green zones, master power control room, water system access control room, guard houses and perimeter fence, and parks, the respective maintenance fees will be covered by the owners per month according to the Condominium’s real maintenance needs, due to which the Condominium Joint Owners’ Meeting shall require a simple majority of attending votes tc establish the extraordinary maintenance fees to cover such real needs, and it will set them according to the square meters of the developed private area of each subsidiary property, i.e., the constructed ;private area of the percentage of ownership compared to the total area of the Condominium. The Condominium Joint Owners’ Meeting will also set extraordinary maintenance fees to cover any extraordinary expenses or needs of the Condominium which are not specified in the approved Annual Budget, and which, due to their nature, must be paid by means of a contribution from all the joint owners according to the percentage of their installed private areas, all of which will be justified by the Administrator to the General Meeting or proposed by any one of the Joint Owners. There shall be no obligation for undeveloped private areas to pay extraordinary maintenance fees. Defaulted extraordinary maintenance fees will be subject to the same late interest specified for ordinary fees. c) Maintenance fee payments: i) Both ordinary and extraordinary maintenance fees must be canceled within the first five business days of each month at the office of the Administrator of the Condominium. ii) The maintenance fee obligation will be charged directly to the Joint Owner, even if he/she/it does not personally occupy the subsidiary property. iii) In the case in which the Joint Owner does not furbish, use or occupy the subsidiary property, and cannot be located by the Administrator to charge the maintenance fee, or if, upon having been located and notified, the Joint Owner does not meet the demanded payment in a preemptory term of five business days after the date of the Administrator’s collection advice, whomsoever does furbish, use or occupy the corresponding subsidiary property under any title will respond for the maintenance fee and late interest, without impairment of the civil nature of the joint and several liability of the Joint Owner. iv) When a subsidiary property of the Condominium is sold or transferred under any title, the seller is under the obligation to present to the Public Notary of record of the sale a certification issued by the Administrator of the Condominium specifying that such subsidiary property is up to date in the payment of its fees under title of shared expenses. If the subsidiary property is in default and the sale is made, the buyer will be considered the joint and several debtor for the amount which will be certified by the Administrator, without impairment of charging the seller the amount that he/she/it owes under this title. d) Maintenance fees of Independent Condominiums: Likewise, when the subsidiary property is also the parent property of an independent condominium, the ordinary and extraordinary maintenance fees of such condominium will be defrayed by means of the proportional payment that the owners of the affiliated subsidiaries must make to the independent condominiums according to the value that their affiliated subsidiary properties represent in comparison to the total value of the independent condominium. The ordinary and extraordinary maintenance fees of the independent condominium must include in their amount the ordinary and extraordinary maintenance fees of Condominic:. Coyol, in such manner that the owners of the affiliated subsidiary properties contribute, proportionally to the payment of the obligations tc, Condominio Coyol 

of the subsidiary property that is the parent property of the independent condominium. Said payments will be made to the independent condominium Administration, which will be in charge of making the full and total payment of the ordinary and extraordinary maintenance fees to Condominio Coyol through the office of the Administrator, while retaining the amount of expenses that are exclusive to the independent condominium for the uses and purposes assigned thereto.
FIFTH CHAPTER. JOINT OWNER RIGHTS AND OBLIGATIONS.
TWENTY-THIRD ARTICLE: On the Rights and Obligations of the Joint Owners: a) The use and destination of the subsidiary properties: The Joint Owners will use their subsidiary properties in accordance with the designated use specified in this Deed of Constitution, and according to the general destination of that Condominium which is made up by land where that is projected for the construction of horizontal, mixed or vertical office, industrial and commercial units, which shall jointly conform ar Industrial Park which is subject to the Free Zone System approved by the Ministry of Foreign Trade and Promotora de Comercio Exterior - PROCOMER. Furthermore, the subsidiary properties may not be destined for uses that are contrary to the law; morals or customs, nor may they serve for any except the expressly agreed use. Joint Owners, lessees, occupants or holders of the subsidiary properties have to remain operating as Free Zone companies, as long as such special regime remains in force and the applicable Law and Condominium Bylaws are expressly modified in order to permit the coexistence in the Condominium of companies that are beneficiary of the Free Zone Regime, and companies that are not. In such case, the Bylaws must be modified unless such amendment to the Bylaws materially affects the financial situation of Zona Franca Coyol, S.A., or the current beneficiary of the Free Trade Zone Regime as Administrator of the Free Trade Zone Park according to Free Trade Zone Law. b) Rules on the joining and division of subsidiary properties: The Joint Owners may unite adjacent subsidiary properties into a single unit under one property title. The division or segregation of such properties will respect the minimum frontage of five linear meters along public streets in the shared areas, and a minimum area for the division of a subsidiary property of three hundred square meters, provided that the divided parts meet all of requisites of the Law and this Bylaw for subsidiary properties. b) Rules for reunion or division of the subsidiary subsidiaries: The joint Owners may reunite adjacent subsidiary properties to form a single unit under a single title of property and may create subcondominiums within the subsidiary properties. For the division or separation of the subsidiary properties, the resulting properties must comply with a Common Area public street front of at least five lineal meters and a minimum area for the segregation of three hundred square meters, provided that all resulting properties comply with all conditions mandated by the Law and by these Bylaws. It is understood that the setbacks indicated by the present regulations, shall be maintained in any case, in relation to the original subsidiary property, and not the resulting property. The same provision applies for Independent Condominiums, where the setbacks shall only remain with respect to the subsidiary property that is the source property of the Independent Condominium. c) Building Quality Standards: The joint owners shall comply with all of the building quality standards of the Condominium as established by its Deed of Constitution, Bylaw, Building Regulations, and the Administrator of the Condominium, which shall be included in and specified on the building plans of approved constructions. d) Private services: The Joint Owners may establish, at their expense, services for their exclusive use, provided that they do not jeopardize or annoy other Joint Owners or the shared areas of the Condominium. On-site building maintenance may be provided by each joint owner, lessee, occupant or holder, under any title. e) Maintenance of private areas: The Joint Owners are responsible for maintaining, cleaning and decorating the on-site private areas that correspond to the subsidiary properties. The maintenance of road surfaces and parking foundations, the internal streets and access ways of each building and subsidiary property that form part of the private area will be the responsibility of each joint owner, as well as the care, irrigation and maintenance of the green areas and gardens within such private areas. f) Forbidden acts: The Joint Owners may not by any act or failure thereof disturb the peace of other joint owners or their private areas, or compromise the stability, safety, health or comfort of the Condominium, or in fact or potentially damage or affect the infrastructure of the Condominium and its shared areas. g) System of Fines: Violation of the Joint Owner ob!iga dons set forth in this clause and in general throughout this Bylaw will result in a fine of TEN THOUSAND UNITED STATES OF AMERICA DOLLARS for the fact of the breach, and the obligation of that joint owner to correct his/her/its breach within a fixed period of thirty calendar days beginning on the date of the written advice from the Administrator regarding the act, a fine and the term for correction. After that term, if the breach persists, the Joint Owner will 

be obligated to pay an additional Ten Thousand Dollars of the United States of America for each month in which said breach persists, and the term of correction of thirty calendar days. A second refusal by the joint owner to pay the fines and correct the breach will produce the request of the Administrator to the competent legal authority which will order the payment of the fines and correction of the joint owner’s breach. The summary procedures established by the Civil Procedural Code are stipulated for processing the claim for payment of the fine by the joint owner, in the case in which it is not paid in good faith, and for processing the correction of the breach, though in this case of intervention by a legal authority, current and late legal interest on the amount of the fine will accrue until the date on which the process finalizes with the corresponding payment, together with procedural and personal costs, which shall be at the expense of the joint owner in breach. The amounts under title of fines that are collected by the Condominium Administration will be applied in the first instance to the Legal Reserve Fund if the corresponding percentage is such fund is not complete, and in the second instance, to approved improvement expenses of the Condominium, all without impairment of those indemnities that legally correspond against the Joint Owner and in favor of the Condominium should the breach thereof cause further damages to the Condominium. h) Obligation to ,avict from the Condominium: Because the Condominium is an Industrial Park subject to the Free Trade Zone System, and regulated by the general obligatory norms related to its nature and use, the obligation of eviction from the Condominium is established within the sixty calendar days following the date on which the following acts are incurred by joint owners, lessees, occupants or holders under any title of a subsidiary property and dully notified by Condominium Administrator: (i) Reiterated violation or breach of the obligations specified by the Ministry of Health for the normal operation of a business established in a subsidiary property in particular; (ii) The disqualification of the Occupant by the Ministry of Health, if its processes and operations are very noisy and generate potential risks of contamination of other nearby companies or residences, or the misuse of the waste water treatment plant, as the result of the violation of the provisions of the Industrial Regulations for Metropolitan Areas published on June Eighteen, Nineteen Ninety-Five, and its future reforms, as well as any other Ministry of Health or other government authority applicable norm, law or regulation which establishes and determines that such company should not continue to operate or that it cannot continue its activities within the Condominium due to its location, nature and use, as an Industrial Park and with the application of the Free Zone System. (iii) The loss of the Free Zone System by causes directly imputable to the Occupant, as long as such special regime remains in force or abandonment of the subsidiary property where the company in particular operates. If such loss where to generate a loss of benefits of the Free Trade Zone Regime to the Administrator, it shall also compensate the Administrator the costs such losses. (iv) Breach in the payment of the maintenance fee to the Condominium for six consecutive months. (v) Repeated damage to the shared areas and services of the Condominium, or a one-time damage that is not duly repaired or compensated by the joint owner, lessee, occupant or holder under any title of a subsidiary property in particular to the Condominium within the term and for the reasonable amount specified by the Administrator and approved by the Condominium Joint Owners’ Meeting. i) General applicability to holders under other title: Any person who holds any title over the subsidiary properties, either as lessees, occupants or holders, or others, will be subject to obey the same obligations established for Joint Owners, who shall ensure their compliance. In case of non compliance, damages or any other action for which fines are applicable, such fines will be imposed on joint owners by Administration, and they will rebound to the lessees, occupants or holders. Nonetheless, if the non compliance damage or other action is attributable to the lessees, occupants or holders of the subsidiary properties, then such person will be will be jointly liable with the Joint Owner and Administration may impose fines and liabilities demandable on then-under this Bylaw. j) Notice of accidents or circumstances that may generate liabilities to the Condominium or Park Administrator: Joint Owners and Occupants shall be required to notify the both the Condominium and the Park Administrator of those circumstances or accidents happening within their subsidiary properties that may generate civil, criminal, or tortuous liability, either directly or indirectly, to the Condominium and/or the Park Administrator. The Joint Owners and/or Occupants shall give notice of said accidents or circumstances within the ensuing twenty-four hours of its knowledge of their happening. Notice to the Condominium and the Park Administrator shall not cause the Condominium and the Park Administrator to have or assume any liability whatsoever, related to such accidents.
TWENTY-FOURTH ARTICLE: Architectural language of the Condominium: Joint owners, lessees, occupants and holder, under any title, will be responsible for constructing their buildings and maintaining their subsidiary properties in suitable conditions that will not jeopardize the Condominium’s general image, due to which they 

will abide by the following provisions:    a) Architecture: The architecture of the buildings it each construction project on a subsidiary property must be harmonious with the architecture of the other existing constructions in the Condominium. The architectural concept consists of managing pure geometric forms and derivatives thereof. b) Colors: The buildings of the Condominium will use suitable colors approved in advance and in writing by the Administration. c) Materials: Top quality materials. will be used in the buildings, particularly the exterior walls will be made of concrete, dry wall or any other material approved by the Administration as stated, except for metal partition walls which wil not be allowed as a primary element., only in specific sections, for expansion purposes or as an architectural accent. d) Fences: The only fences allowed are live hedges with a maximum height of one point five meters along the borderlines of each property, prior Administration authorization. Under no condition will the construction of solid railings or cyclone fencing be authorized, except around the external perimeter of the Condominium or to protect restricted access areas. In this latter case, they must be covered with the appropriate material, with greenery or a material similar to black saran. e) Signage: For businesses to place signs, they must have Administration authorization. The signs must have a compatible architectural design with the building that they identify. The materials, finishes and colors, but those of the logos, or trade marks of the companies, must coordinate with those of the building, and be located in areas designated by Administration for that purpose. Sign illumination must not be flickering. The sign shall be limited to the name of the company and may include its logo and information of the product to be provided by the Joint Owner. It may be located in a concrete structure at ground level. Signs hanging from the ceiling, main walls or posts are not allowed. Flag poles may be installed, providing that they do not exceed 10 meters in height and the size of the flags must not exceed 150 centimeters by 300 centimeters. The size of the signs will be related to the front dimension of the building and the printed area of it will have a maximum of 2 meters long, by 1.5 meters high, per every 50 meters of front of the building. The Sign shall be limited to the name of the company, may include its logo as well as product information and the Free Zone Park address information. The Administration may approve signs in large pedestals and walls as well as increase the maximum dimensions in proportion to the length of the side front of the building. f) Paint: The Joint Owners will be responsible for maintaining their buildings or industrial units and expansions suitably painted, in such manner that they do not jeopardize the image of the Condominium and they shall paint the exterior of the buildings at least every three years at the expense of the Joint Owner. No occupant or Joint Owner may paint the buildings or industrial units that it occupies a different color than those described previously, unless it receives the express and written authorization of the Administration. Likewise, the colors of complementary works must be previously approved by the Administration in witting g) Building Facade: No occupant or Joint Owner may change the fagade of the buildings without the express written, prior authorization of the Administration. h) Other Regulations: No electromechanical equipment, including meters, may be exposed on the main front wall surfaces of the buildings. Corrugated tin par+:ition wa Ils are allowed provided they are used as architectural accent elements designed according to the general architecture of the Condominium, or prior written approval from the Administration. All power equipment shall be located in such a way that is not visible from the main street, with the exception of those that due to electrical standards must be placed in front of the building such as meters, shunts and transformers. Air conditioning, others and chimneys may be placed on the roof provided they are not visible from the centerline of the main street opposite the main façade of the building. If necessary they shall be covered by parapets, screens or similar structures that integrate well with the architecture of the building. In the case of their being placed on the roof or the lateral side of the building, must be placed at points that are not visible from the centerline of the main street opposite the main façade of the building, and always covered by parapets, screens or similar structures if necessary. The roofed area of the buildings may not exceed 50 percent of the total area of each individual parent property. I) Setbacks: All filial lots will comply a setback of 5.0 meters from the internal side of the street sidewalk ..=or any building or any other type of installation under 5 meters in height, in order to maintain a harmonious and ample green buffer to the sidewalk and streets. This area is exclusive for landscaping purposes and there will not be constructions or equipments in this area, except for those required for basic building services, including disconnecting switches, measurement modules and transformers of public lighting, and all those required by electrical standard, as well as access roads or sidewalks, or by a special permit from the Administration. The street front setback of the buildings will be az least another 12 meters from the above mentioned line and the lateral and back setbacks will be 5 meters from the property line of the individual parent property as a minimum. No building may exceed 35 meters in height and for buildings higher than 2 floors, the approval by the National Civil Aviation Administration, is required to begin construction, due to the area where the Condominium is located in general near the Juan 

Santamaria Airport:. Such permit shall be delivered to the Administration for the start up of the respective construction. For any building or any other type of installation over 5 meters in height, and which is adjacent to the property line of another subsidiary property, the property line setback will increase 1 meter for each meter of additional height; the street front clearing will be remain same. The benchmark for the building height will be the average road elevation in the street front of the lot and the gutters height. In case of multiple street fronts, the lobby facing front road will apply. Under no condition will the construction of solid railing or cyclone fencing, with the exception of the external perimeter fences or to protect restricted access areas of the Condominium, be authorized. In this latter case, the fences must be covered with suitable materials, either greenery or a black saran-type material. No mechanical or power equipment nor the parapets, screens or similar structures that may cover them, shall be considered a construction therefore it will not generate setbacks, and shall not be exposed or showing on the wall surface of the subsidiary properties or future buildings. When meters, electrical switch boxes, pedestal transformers or other public utility connections are needed, they must blend with the infrastructure or the building, in cases when such exist, regarding the future development of the stages of this Condominio Coyol, and inasmuch as possible, they shall be hidden by materials that blend with the architecture or landscape of the infrastructure or building accordingly, unless that public institutions that facilitate the corresponding public services require something different. Equipment will not generate setbacks. Large equipment must be placed in machine rooms with walls with a minimum height of 2.0 meters so that they blend with the infrastructure, architecture and landscape of the building of each subsidiary property, if required in specific cases. Exposed fire water storage tanks, cooling towers, and similar equipment are allowed, and generators can have their own isolated cabinet that shall be part of the equipment and not as a construction that generates setbacks. The eaves and covered passages should not generate setbacks, as long as their design is compatible with the architecture of the park and the building, and have been accepted by the Administration. Additionally, all roofed pedestrian passes can reach the sidewalk of the main infrastructure they serve. In relation with the setbacks and limitations established on this clause, the Administration shall not reject any construction authorization request that respects the minimum setbacks and limitations established hereto. j) Construction: To maintair the image of Condominio Coyol, all construction it the exterior of the building shall be executed Prior approval from the Administration of the Condominium, it must be fenced in and have controlled worker and equipment and materials entry and egress, which details are stipulated in this. Bylaw. Also, the joint owners who engage the construction projects shall meet occupational safety norms guaranteeing the least number of accidents. possible, and they must also comply with the environmental standards of the Condominium which will be specified later in this Bylaw. The owner of the construction project will be liable for ensuring that the subcontractor who executes the project does not damage the installations or structures of the Condominium, the private anc shared assets, and for guaranteeing the conservation of the ornamentation and cleanliness of the Condominium at all times. The joint owner who engages the construction work will be charged all of the inherent expenses for the replacement„ repair, damages and necessary extraordinary maintenance that is directly or indirectly produced by the construction project, independently of if it is caused by an outside contractor. Failure to pay such expenses to Condominium Administration according to the breakdown provided by Administration to the Joint Owner, within .5 business days beginning on the day following notification from the Administrator, will accrue late interest at the same rate as was set for the Ordinary Maintenance Fee by the Condominium Joint Owners’ Meeting. k) Gardening and landscaping: The joint owners shall maintain their private greer areas in a similar natural setting as the green areas of the common areas of the Condominium and it accordance with the Construction Regulations. The Joint Owners will be responsible for maintaining the automatic sprinkler systems and hydrometers at their subsidiary properties. In no case may the joint owners maintain vegetation in their private green areas which could or may reasonably be expected to produce bad odors, sanitation or ornamentation issues, or which could damage the external or sub- surface infrastructure of the Condominium, the shared or private installed services or systems of other joint owners. In such case, the Condominium Administration will caution the joint owner tc immediately and definitely withdraw the damaging or potentially damaging or problematic vegetation. The total area of landscape shall be not less than 10% of total land. In relation with gardening and landscaping limitations established on this clause, the Administration shall not reject any construction authorization request that respects the minimum landscape percentage established hereto. I) Utlities: All utilities connections shall be underground. Screening of the above-ground utility equipment a seen from on or off-site is required. TV antennas or telecom satellite dishes are to be hidden from street view, as other mechanical equipment.

TWENTY-FIFTH ARTICLE: Prohibitions: a) Animals: It is forbidden to keep animals of any type in the Condominium, except those which may be used by security, or work dogs required by handicapped people, and which will be exclusively for the purposes thereof. b) Substances and materials: Also, it is forbidden to keep inside of the Condominium any type of substance or product, either chemical or natural that produces bad odors or may endanger the welfare and safety of people and buildings, and other structures and works of the Condominium. Therefore, it is forbidden to possess:3 any unsanitary materials, which produce bad odors, smoke or any disturbance, or which may endanger health, with the exception of those from the operation of the industrial plant installed on each subsidiary property and its corresponding production processes, which will have previously been reported to and authorized by the Condominium Administration or the Condominium Joint Owners’ Meeting, if the Administrator should find it necessary to place the matter before it for its knowledge and approval. Flammable or chemical materials, or any material who may explode, or generate high risk, should be reported to the Administrator together with a note of compliance of the Health Department Storage requirements and any other Fire Department or Environment department compliances that may be needed. c) Food consumption: No person may use the sidewalks, streets or green areas to ingest food. The joint owners, lessees, occupants or holders, under any title, must ensure the correct abidance of this article. In the shared recreational areas of the Condominium, exclusive areas will be installed where food may be consumed during social, sports events or at lunch hours, the use of which for specific activities must be requested by the joint owners in advance and in writing from the Administrator, after which they shall not engage in any activities other than those originally proposed and approved, meaning that in the case of requiring any modification, Administration shall be notified in writing and its prior approval newly obtained. Each joint owner, lessee, occupant or holder, under any title, of a subsidiary property must destine part of the private area to the food requirements of staff and visitors, generally in accordance with the applicable Ministry of Health regulations. d) Industrial sewage: The Condominium has its own waste water treatment plant, the use and limitations of which are binding on all the Joint Owners, lessees, occupants or holders under any title. Therefore, it is forbidden to allow industrial sewage to run free, especially in the following cases: d.i) It is forbidden to discharge untreated industrial waste into the sewers of the Condominium. Administration may authorize such discharge prior authorization from the Ministry of Health and within the limits of the treatment system. d.ii) It is forbidden to discharge sewage, runoff and industrial residues into the pluvial drainage system of the Condominium. e) Obstruct of Common Areas and Circulation Areas: .Transit areas, including but not limited to sidewalks, entrances, passageways, elevators, stairs, lobbies and other common transit areas, and common areas of the Park may not be obstructed, with equipment, vehicles, machinery, raw materials or any goods or debris owned or created by each Joint Owner or its contractors, lessees, employees, dependents or visitors, or any other person related with it, or used or occupied differently than for the entrance or exit of machinery, material, equipment, goods, vehicles or persons, as may be the case, with the activities developed by the Joint Owner. The Administrator of the Park will charge a fine of 25 dollars, per incident for parking and/or obstruction violations of these provisions, plus the cost of the obstruction removal resulting from the non-compliance with this provision. The 25 dollar fine may be adjusted by the Condominium Joint Owners meeting from time to time.
TWENTY-SIXTH ARTICLE. The obligation of the Joint Owners for environmental conservation: All of the joint owners, lessees, occupants or holders, under any title, are obligated to contribute to the betterment and maintenance of the environmental conditions that meet the vital and health needs of neighboring populations, such as by the good and healthy habits of their workers. No establishment may operate in the Condominium if it constitutes a nuisance, danger, or if it fosters unhealthy conditions in the area, either because of the maintenance conditions if its industrial unit, the systems that it employs in its operations, because of the way it eliminates wastes and emissions, or because of the noise that its operation produces. As a result, no companies may operate in the Condominium which, due to the nature of their business or the conditions in which it is conducted, the materials or wastes employed, elaborated or emitted, or which due to the storage of toxic, corrosive, inflammable or explosive substances, could produce effects capable of jeopardizing or effectively damaging, in an immediate and serious manner, the environment, installations and structure of the Condominium, the lives of the inhabitants or neighboring populations of the Condominium. All of the joint owners, lessees, occupants or holders, under any title, of the Condominium’s subsidiary properties, businesspeople, workers, administrative staff and visitors, are obligated to abide by the environmental commitments that govern the Condominium and which are set forth in the Environmental Impact Study of the Coyol Free Zone Project, which was submitted and 

approved by the National Environmental Technical Secretariat -SETENA, by Resolution Number SG-2864-2006 SETENA, by the original owner of the property which was put under the Condominium Property System in this deed for the creation of the Condominium, ZONA FRANCA COYOL SOCIEDAD ANONOMA, Corporate Identification number 3 - 101 - 420512, which environmental commitments form an integral part of the Bylaw and a copy of which is given to each joint owner together with the Bylaw for their due information and strict abidance. The joint owners, lessees, occupants or holders, under any title, whose activities are disturbing, unhealthy or dangerous and which operate irregularly may be closed down by the health authority without Administration liability, and in each case, its owners and administrators will be obligated to comply with the orders or instructions of the health authority for the purpose of putting and end or mitigating the unhealthy, dangerous or disturbing conditions produced thereby. It is the obligation of the Occupants to place in service, in the installations that they occupy, the equipment and systems that are necessary to avoid the discharges, emissions, emanations or noise that their operations cause and which generate contamination. Also, it is the obligation of the joint owners, lessees, occupants or holders, under any title, to have fire and other natural disaster prevention systems as required by the Fire Department, National Emergencies Commission, and the National Insurance Institute, as well as having systems to avoid interior environmental contamination that could jeopardize the health and welfare of their staff and others.
TWENTY-SEVENTH ARTICLE: Trash or solid waste bins: The Condominium will provide trash bins along sidewalks and pedestrian walkways. Each building must have trash bins that are suitable to its volume, which must be located in a zone authorizec in writing by the Administrator and which is not visible or screened from street view. The location must be in a place and in a container which minimizes odors or noise to the neighboring subsidiary properties. The Administrator will coordinate solid waste collection services through private waste collectors who are authorized by the. corresponding State agencies. The Occupants of the Condominium will be obligated to use the trash collection system provided by Administration, due to which it is forbidden for any individual or company to dispose of or accumulate solid waste in places that are not expressly authorized for that purpose, to use unsuitable means of transportation or accumulation, and to proceed to use, treat or finally dispose of waste by means of systems that have not been approved by Administration under the norms established by the Ministry of Health, Municipality of the Central Canton of the Province of Alajuela, and by the trash collection company. The Condominium will provide solid waste bins located in shared green areas and strategic places. Administration will be responsible for maintaining the optimum condition of the bins; however, joint owners, lessees, occupants or holders, under any title, will collaborate in promoting the adequate use and care of such bins among their staff and visitors. The trash generated by each joint owner, lessee, occupant or holder, under any title, operation, must be deposited in the easy-access enclosed bins that are provided to them in each subsidiary property and placed in specific areas only on those days when trash is collected. The location of such bins will be in an area that is protected from view from the main street and which shall avoid bad or trashy odors. In the case of toxic, metal, or other types of waste that are not admissible in the sanitary landfills where the Condominium will send its waste, the respective joint owner must hire a supplier authorized by the Ministry of Health, and it will he under its responsibility, risk and expense that such waste will be removed. To cover the trash collection expenses of each joint owner, the terms of the Twenty-Second Article, paragraph a) Ordinary Maintenance Fee, sub-paragraph a.vii) will apply.
SIXTH CHAPTER. ON ACCESS INTO THE CONDOMINIUM.
TWENTY-EIGHTH ARTICLE: Control and Registration of Persons and Vehicles: In view that the Condominium is a Corporate and Industrial Park which is subject to the Free Zone System, with its respective customs controls, strict control of entry and egress of vehicles and persons, is an essential part of the Condominium’s security system. The entry and egress of vehicles, persons, administrative and regular staff, shall register at the security gate located at the entrance of the Condominium, and shall provide the identification that the Administration shall provide for such purposes, as means of access required to allow control and facilitate permanent access to such vehicles and persons and according to the following provisions: a) Entry of vehicles to the park: Only passenger cars belonging to the following people may enter the Condominium, provided those people are duly authorized and identified: executves and workers of the companies, buses for the transport of such workers, PROCOMER staff, General Customs Direction, Ministry of Health, Ministry of Labor, Ministry of 

Public Security, Ministry of Treasury, Ministry Economy, Industry and Commerce, Internal Revenue Service (Direction General de Tributacion Directa) and personnel working with Administration. In order to enter the Condominium, such vehicles shall be duly registered with the Administration, who shall have a record of the cl,-iver’s name, identity card or passport number, origin, address, which shall provide them with an identification and assign them an access door allowing an appropriate control and facilitating the permanent access of said persons. The customs station may request an inspection of a vehicle, at its discretion. Any other vehicles not included in this article shall need an appropriate authorization in order to enter the Condominium, issued by the Administration or by a representative of the company they are visiting. In the case of other cars or trucks necessary for the development or operation of the Condominium, such as those vehicles used for the transportation of raw materials, components or finished products that are subject to customs control, or in the case of visitors in general, drivers shall identify themselves at the security or customs checkpoint, as appropriate, and they shall be registered in a book, indicating the driver’s and passengers’ name, identity card or passport number, origin, address, purpose of the visit and entry and exit time. In order to leave the Condominium, every unidentified vehicle shall stop at the surveillance post to be registered by the security guards, who may authorize the vehicle to leave, or who may refuse its exit if any anomalies were found. b) Driving and parking. Vehicles entering the Condominium shall respect the speed limit indicated in the street signs posted throughout the Condominium; they shall also respect the speed limit for pedestrian zones (40 Km/p/h). Drivers shall use the parking spaces. Vehicles shall not be allowed in other areas, such as access to each company, loading/unloading zones, or those in front of bus stops, hydrants or any other restricted areas according to general provisions, laws, regulations and road signs. Administration reserves the right to tow away any ill-parked vehicles, and the owner of the car will pay the respective expenses plus a 25 dollar fine, fine that may be adjusted by the Condominium Joint Owner’s Meeting from time to time. The Administration shall not be responsible for any damages resulting from said action. Trucks or trailers transporting raw materials, components or finished products shall park on the dock belonging to each company. Parking trucks and trailers on public roads, streets and accesses to the Condominium is strictly forbidden; the parking spaces for passenger cars are not intended for trucks. In case the docks assigned to a company were not enough, trucks and trailers shall wait outside the Condominium, unless the Administration assigns them another dock or a temporary parking area. All traffic and parking laws and regulations shall be applicable within the Condominium. c) Exit of vehicles and containers or other type of sealed vehicles. To leave the Condominium, all unidentified vehicles will stop at the guard station to be registered internally by the guards who will authorize the egress of the vehicle, which may be denied if any anomaly is encountered, in which case it will immediately be reported to Administration. For the egress of containers or other types of tagged vehicles, the security post of the Condominium will corroborate that any vehicle that exits is carrying the exit documents that are required by the General Customs Service, and will review the tag number against the one specified on the Customs documents. Furthermore and continuing along the same vein, the security officer that makes the verification will note the following information in the book of egresses: name of the driver, transport company, vehicle license plate, type of vehicle, tag number, Customs policy number, issuing Free Zone Company, and time of egress. This does not disallow requests for information that the Ministry of the Treasury, General Customs Service, Promotora de Comercio Exterior or Administration may require for good vehicular egress control. Conditionally and in coordination with the Customs post, outgoing cargo vehicles may be searched. c) Vehicles of the executives, administration personnel, or employees: In case of vehicles belonging to the executives, administration personnel, or employees, the Administration shall give them a label and an I.D. valid for one year that shall entitle them to enter and leave the Park. Security may stop, randomly, any of these vehicles and check their trunk and interior. In case any irregularities are found, they shall be reported to Administration and customs for the appropriate actions. In case of recidivism or a more serious infraction, the administration may withdraw the sticker, and the vehicle shall undergo inspection every time it leaves the Condominium. d) Entry and exit of persons to and from the Condominium. In order to control the entry and exit of persons to and from the Condominium, the Occupants and the administration shall give their employees an I.D. that shall contain, at least, the following information: Company name, full name of worker, identity card number or passport number, recent photo, authorized seal of the company and date of issuance. I.D.’s shall be valid until December of each year, and that month the lists and validity shall be updated. Administration shall provide said I.D.’s, paid by each company, and it shall be the company’s responsibility to immediately notify if an employment contract expires, in order to control the access of said person. The Occupants shall be responsible for the merchandise belonging to them or being under their custody.    Nevertheless, security may randomly inspect the purses, bags 

or briefcases of workers or visitors if they deem ii appropriate. Any irregularities found shall be informed to Administration, and Administratior shall inform the customs office and the affected company, as appropriate. If the Administratior where to install proximity card access and exit systems, the Occupants shall provide the Administration all required information of its employees, for the efficient functioning of said system. The cards shall be at the Occupants, expense. e) Entry and exit of administrative staff and executives and workers of the companies. The administrative staff, executives and employees of the companies may freely enter the Condominium during working hours. Nevertheless, they shall carry the special I.D. mentioned in the previous article and use the accesses designated by the administration for said purpose, having to show their I.D.’s. f) Entry of visitors. In order to enter the Condominium, visitors shall identify themselves at the surveillance post, giving their persona, information and telling the object of their visit. Once the security guard has recorded said information, and after verifying with the Company Installed in the Condominium, he shall deliver a visitor’s I,D, that the visitor shall wear in a visible place while he/she remains in the Condominium. The surveillance post shall keep a record of the visitors in the appropriate book, where the following information shall be recorded: visitor’s, name, identity card or passport number, license plates, company being visited, entry and exit time.
g) Entry of salespeople. Except when the administration issues an express authorization, the entry of all types of salespeople to the Park is forbidden, including street vendors.
SEVENTH CHAPTER: MISCELLANEOUS:
TWENTY-NINTH ARTICLE: General regulation which the joint owners shall abide: In view that the Condominium is an Industrial Park subject to the Free Zone System, and that on the date when it was, subjected to the Condominium Property System it obtained the respective approvals from the regulatory public agencies, such as, withoul limitation, the Ministry of Foreign Trade, Promotora de Comercio Exterior PROCOMER, the Nationa, Environmental Technical Secretariat SETENA, the General Customs Service, the Ministry of Health, “INVU”, “IMAS” and the institutions that provide approval for the Condominium Property System, the joint owners who acquire a subsidiary property in the Condominium also acquire a property subject to the general inalienable regulations regarding the nature,. use, structural and organizational make-up of the Condominium which they must abide by at all times. Consequently, the Joint Owners are obligated to abide by the stipulations contained in the Law and Bylaw, those of the Internal Rules of Operation of Zona Franca Coyol S.A., as approved by PROCOMER and the Coyol Free Zone Master Plan a copy of which has been attached to the Notarial Book of References of Notary Soto Mora as a reference document, the environmental commitments that govern the Condominium and which are set forth in the Environmental Impact Study of the Coyol Free Zone Project, which was submitted to the approval of the National Environmental Technical Secretariat by means of its Resolution Number SG-2864-2006 SETENA, by the original owner of the rural property that was subject to the Condominium Property System in this deed for the creation of the Condominium, ZONA FRANCA COYOL SOCIEDAD ANONIMA, Corporate Identification number 3 - 101 - 420512, the General Health Law, its reforms and Bylaw, and Free Zone Law Number seven thousand two hundred ten, its reforms and bylaws, as well as by General Customs Law Number seven thousand five hundred fifty-seven, its reforms and bylaws, and all of those laws and regulations that apply to the subject and activity. Joint Owners and Occupants shall also keep all their functioning permits in effect always. The Administrator will provide the joint owners with an information pamphlet that will contain this Bylaw, the internal Rules of Operation of Zona Franca Coyo! S.A., the Coyol Free Zone Master Plan, and the environmental commitments acquired by the Condominium before SETENA. Nevertheless, no joint owner may allege ignorance of the stipulations and regulations to which he/she/it is subject because of the fact that the Administrator does no provide such information, since the joint owner, upon acquiring the property and consequently all of the obligations specified in this Bylaw, will be subject to strict compliance and it shall be his/her/its individual obligation to be duly informed and gather the regulations that have been mentioned. Breach by the joint owner of any of the stipulations that govern the Condominium will be put before the Condominium Owners’ General Meeting, which will determine the measures and sanctions that will be imposed on the respective joint owner.
THIRTIETH ARTICLE: On the affectation of the subsidiary properties to the Condominium Property System: In view of the legal nature of this Condominium, that is, that each subsidiary property represents a 

stage of construction and each one of them may be submitted individually to the Condominium Property System thus creating Independent Condominiums which will be joined by the shared areas of Condominio Coyol, the owners of the subsidiary properties which wish to submit their property to the Condominium Property System under the Law, shall abide and ensure compliance with the terms, conditions and provision contained in this Bylaw by the joint owners, lessees, occupants or holCers, under any title, of the resulting Independent Condominiums. Likewise, they shall include in their own regulations all obligations that as Joint Owners of this Condominium they have accepted and acquired. Breach of the stipulations herein will be considered a serious violation of this Bylaw and will empower the Condominium Joint Owners’ Meeting to demand compliance.
THIRTY-FIRST ARTICLE: Modification of the Bylaw: Any modifications of this Bylaw, be it total or partial, may only be executed by the Condominium Joint Owners’ Meeting according Law and by means of resolutions taken by unanimous vote of all the owners or joint owners of the Condominium. Every modification must be registered in the Public Registry and shall be informed by Administration to the joint owners. The Condominium Joint Owners’ Meeting will be the only responsible body to interpret this Bylaw, and such interpretation will be binding on the parties. To determine if the interpretation is reasonable or not, the opinion in that regard specified in writing by the legal advisors of the Condominium’s Legal counsel will suffice. The lack of validity or efficiency of one or more of the stipulations of this Bylaw will not cause the lack of validity and effect of the remaining stipulations hereof.
THIRTY-SECOND ARTICLE: Extinguishment of the Condominium Property System: The extinguishment of the Condominium Property System may take place by resolution of the Condominium Joint Owners’ Meeting, by unanimous vote of all the subsidiary property owners of the Condominium, providing that such extinguishment does not disobey other legislation related to the subject, particularly in regard to the possible remaining lots or units. The extinguishment of the system will take effect from its registration in the Public Registry. In that case, the entries of the parent property and subsidiary properties will be cancelled in the Condominium Properties Section and the new immovable properties will be registered in the General Properties Section. The acquired rights of third parties will remain intact.
THIRTY-THIRD ARTICLE: Recognition of Cytyc Surgical Products Costa Rica, S.A. Lease Agreement: This Condominium Declaration recognizes the existence of that certain Lease Agreement (the “Cytyc Lease Agreement”) executed on April 23, of the year two thousand and seven, by and between Cytyc Surgical Products Costa Rica, S.A.(“Cytyc”), and Zona Franca Coyol S.A., which certain clauses, terms and conditions are protected by a Non Disclosure Agreement executed by both executing parties of Cytyc Lease Agreement. The approval of this Condominium Declaration, any amendment to it or any resolution by any Condominium Committee shall not be deemed to affect or otherwise limit the rights granted to Cytyc according to the permitted uses set forth in the Cytyc Lease Agreement in the filial properties 23 and 24. Pursuant to the Cytyc Lease Agreement, and as long as such Lease is in effect Cytyc will not be required to make any additional payment related to condominium fees or any other payment imposed by the Condominium to the Joint Owners other than those established in the Cytyc Lease Agreement, and will not be required to make payments as indicated in Article 21 above. Cytyc will not be jointly liable with the Joint Owners, to pay fees generated from the non compliance or damages as established in Article 23, Section i) above, when they are not attributable to Cytyc; nor will Cytyc assume any Joint Owner obligation that is not contemplated in Cytyc Lease Agreement. Also Cytyc may not be evicted from filial properties 23 and 24, for the non compliance by the Joint Owners of its obligations to repair damages to shared areas and services of the Condominium, if the such damages are not attributable to Cytyc. If any such damages are attributable to Cytyc, Cytyc will have to repair in accordance with the Lease Agreement. It is expressly recognized that, since Cytyc Lease Agreement was executed prior to the execution of this Bylaws, in case of discrepancy between the provisions of such Lease Agreement and the present Bylaws, as expressly created on this date, Cytyc Lease Agreement conditions will prevail.
TO HERE THE BYLAW OF CONDOMINIO COYOL.

Exhibit 5
Usage regulation of the Sewage Treatment Plant.

Exhibit 6
Additional Monthly Service Fee.

Additional Monthly Service Fee for
Building Maintenance & Free Zone Administration Services:
Tenant will pay an additional monthly service fee to Landlord of thirty two cents of dollar (US$0.32), legal tender of the United States of America, per leased square meter of construction area as a for Building Maintenance and Free Zone Administration Services. Services included in this fee are:
i)    General maintenance of the cold shell building including but not limited to: a) roof maintenance; b) water filtrations; c) building exterior concrete shell; d) Building floor and tiles due to normal tear and wear.
ii)    Premises parking areas maintenance
iii)    Municipal taxes based on Premises value on Commencement Date
iv)    Cold Shell Building insurance base on Premises value on Commencement date

Exhibit 7
Wire Transfer Information.

WIRE TRANSFER INFORMATION
A.    INTERNATIONAL WIRE TRANSFER
	
		
	International Wire Transfer

	Bank
	The Bank of New York
1 Wall Street, New York, NY
10286

	ABA
	021000018

	SWIFT
	lRVTUS3N

	For Credit to account number
	8033383577
Banco Scotiabank de Costa Rica
S.A.
San Jose, Costa Rica
SWIFT: NOSCCRSJ

	For Final Credit to account number
	0311452701
Zona Franca Coyol S.A
Alajuela, Costa Rica

	Please instruct The Bank of New York to send a SWIFT message MT103 to Scotiabank de Costa Rica S.A. SWIFT NOSCCRSJ

B.    LOCAL WIRE TRANSFER
	
			
	 	Informacian de la Comparila

	 	Nombre Completo de la Empresa
	Zona Franca Coyol S.A.

	 	Cedula Juridica
	3-101-420512

	 	Telefono
	2432-0557

	 	Fax
	2435-6060

	 	Contacto Cuentas por Cobrar
	Karen Viquez o Leslie Saborio

	 	Direccion electronica

	 
	 	Informacion Banicaria

	 	Nombre del Banco
	Scotiabank de Costa Rica S.A.

	 	No. Cuenta Corriente
	0311452701

	 	No. Cuenta Cliente
	12300003114527010

Exhibit 8
LOI dated February 23rd,2015

Exhibit Nine
Letter of Credit

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00285-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00285-of-00352.parquet"}]]