Document:

exv10w11

 

EXHIBIT 10.11

CONSULTING AGREEMENT

     THIS CONSULTING AGREEMENT (the “Agreement”) is made the twelfth day of September, 2005
(the “Effective Date”), by and between Pro-Vision Development Corporation of Eldora, Iowa
(“Pro-Vision”) and NEK-SEN Energy Partners, of Sabetha, Kansas, a Kansas Partnership (“Client”).

     WHEREAS, Client intends to develop, finance and construct an ethanol plant in or near Sabetha,
Kansas (the “Project”); and

     WHEREAS, Pro-Vision has a background in developing and financing ethanol plants and is willing
to provide services to Client based on this background.

     NOW, THEREFORE, in consideration of the mutual promises and agreements contained herein,
Client hereby engages Pro-Vision, and Pro-Vision hereby accepts engagement, upon the terms and
conditions hereinafter set forth.

     1. Term. The Pro-Vision engagement with Client shall commence as of the Effective
Date and may be terminated at any time by either party upon thirty (30) days prior written notice
of its intent to terminate this Agreement. Upon termination, neither Client nor Pro-Vision shall
have any further rights or obligations under the terms of this Agreement other than delivery of
payments for services to which Pro-Vision may be entitled through the date of termination.

     2. Services. Pro-Vision shall serve as the Client’s consultant and shall perform the
following duties incident to that service subject to Client’s approval:

a. Consult with the officers and employees of the Client concerning matters
relating to the planning and development of a 50 MGY renewable fuel ethanol plant;

b. Provide Project Coordination services, providing management and oversight in the
Client’s directive to establish a separate LLC or Limited Partnership company that
will develop, own and operate the production facility, if applicable; and

c. Perform such other reasonably necessary duties as Client may request for the
timely and successful securing of debt financing; including without limitation,
cooperating with the Client’s personnel, consultants and agents similarly engaged.

d. Perform management and oversight representing Client in the construction
development of the project, including but not limited to: management of employees
and consultants in budgeting, permitting, request for proposals, contracting and
overall Construction Coordination.

     It is anticipated Pro-Vision will spend approximately 10 to 100 man hours per week in
fulfilling its management obligations under this Agreement. The particular time may vary from day
to day or week to week.

     3. Payment. Client shall pay to Pro-Vision a one time commitment fee of $ 15,000 and
$1,800 per week for service performed hereunder commencing upon the Effective Date. The weekly base
payment shall be due*. Upon termination of this Agreement, payments hereunder shall
cease; provided, however, that Pro-Vision shall be entitled to payments for periods or partial
periods that occurred prior to the date of termination for which Pro-Vision has not been paid. In
addition, if the triggering event has occurred prior to the effective date of his termination,
Client shall pay to Pro-Vision the following:

a. Business Plan Bonus. Client will pay to Pro-Vision a success bonus of
$20,000 (the

 

*Biweekly [/s/GE; /s/MC]
 

1

 

“Business Plan Bonus”) due immediately upon the Client’s acceptance of the Business
Plan from Pro-Vision as complete.

b. Loan Commitment Bonus. Client will pay to Pro-Vision a success bonus of
$75,000 (the “Loan Commitment Bonus”) payable upon Client’s final acceptance of the
senior loan commitment and all additional equity and/or subordinated debt required
by such loan commitment.

c. Loan Closing Bonus. Client will pay to Pro-Vision a success bonus of
$100,000 (the “Loan Closing Bonus”) at the time of execution of the definitive
documents defining the Clients senior loan. Notwithstanding the foregoing, the
Client shall have sole discretion in determining whether to accept a loan commitment
or close a loan, and the Client shall not become liable to pay the amount discussed
in this Section 3d if it elects to not accept a loan commitment or close a loan.

e. Construction Completion Bonus. Client will pay to Pro-Vision a success
bonus of $ 50,000 (the “Construction Completion Bonus”) at the time of Substantial
Completion by prime contractor/design builder.

     4. Expenses. Client shall reimburse Pro-Vision for all reasonable, ordinary and
necessary expenses incurred by Pro-Vision in performance of its duties hereunder, including without
limitation, reimbursement for automobile mileage at a rate periodically set by the Internal Revenue
Service (presently 40.5 cents/mile), phone and a mutually agreed upon per diem for lodging and
meals. However, in no case shall any such expense reimbursements exceed $950 in any single week.
Payment for expenses will be paid 14 days after receipt by Client from Pro-Vision of expenses due.
All other expenses incurred by Pro-Vision under the direction of Client in development of project
such as air travel, meeting expenses, copy, postage and office materials utilized remotely from
Client supplied office will be reimbursed at cost and will not be within weekly limitation
previously defined.

     5. Support Services. Client will provide the following support services for the
benefit of Pro-Vision as approved by Client: office space, office equipment, supplies and
administrative support such as accounting and secretarial.

     6. Successors and Assigns Bound. This Agreement shall be binding upon the Client and
Pro-Vision, their respective heirs, executors, administrators, successors in interest or assigns,
including without limitation, any partnership, corporation or other entity into which the Client
may be merged or by which it may be acquired (whether directly, indirectly or by operation of law),
or to which it may assign its rights under this Agreement.

     7. Relationship of the Parties. The parties understand that Pro-Vision is an
independent contractor with respect to Client and Pro-Vision agents do not represent employment of
Client. Client will not provide fringe benefits, including health insurance benefits, paid
vacation, or any other employee benefits for the benefit of Pro-Vision.

     8. Injuries. Pro-Vision acknowledges Pro-Vision’s obligation to obtain appropriate
insurance coverage for the benefit of Pro-Vision and its agents. Pro-Vision waives any rights to
recover from Client for any injuries that Pro-Vision or his agents, may sustain while performing
services under this Agreement resulting from the negligence of Pro-Vision or his agents.

     9. Property and Return of Records. Upon termination of this Agreement, Pro-Vision
shall deliver all records, notes, data, memoranda, models, and equipment of any nature that are in
Pro-Vision’s possession or under Pro-Vision’s control and that are Client’s property or relate to
Client’s business. This article shall be reciprocal where Client shall return or keep confidential
all such similar articles of Pro-Vision rights of ownership to Pro-Vision upon termination of this
Agreement. Such articles include documented intellectual
property such as “Developing a Renewable Fuels Project from Grass Roots” and such
other

2

 

documents so defined and marked as Pro-Vision property and which are not public record.
 

     10. Waiver. The waiver by the Client of its rights under this Agreement or the
failure of the Client promptly to enforce any provision hereof shall not be construed as a waiver
of any subsequent breach of the same or any other covenant, term or provision.

     11. Entire Agreement. This Agreement constitutes the entire Agreement between the
parties hereto with regard to the subject matter hereof, and there are no agreements, understanding
specific restrictions, warranties or representations relating to said subject matter between the
parties other than those set forth herein or herein provided for. No amendment or modification of
this Agreement shall be valid or binding unless in writing and signed by the party against whom
such amendment or modification is to be enforced.

     12. Notices. Any notice required to be given hereunder shall be in writing and shall
be deemed to be sufficiently served by either party on the other party if such notice is delivered
personally or is sent by certified or first class mail addressed as follows, or such substitute
street addresses as the parties may provide in writing:

	 	 	 	 	 	 	 
	 

	 	To Pro-Vision:
	 	Pro-Vision Development Corporation	 	 
	 

	 	 	 	Attention: Matt Crouse, President	 	 
	 

	 	 	 	1801 17th Avenue	 	 
	 

	 	 	 	Eldora, IA 50627	 	 
	 
	 	 	 	 	 	 
	 

	 	To Client:
	 	NEK-SEN Energy Partners	 	 
	 

	 	 	 	Attention: Gary Edelman	 	 
	 
	 	 	 	 	 	 
	 

	 	 	 	 

Sabetha, Kansas
	 	 

     13. Governing Law. This Agreement is entered into pursuant to and shall be governed
by and in accordance with the laws of the State of Kansas.

     IN WITNESS WHEREOF, the parties hereto have executed this Agreement on the Effective Date.

	 	 	 	 	 	 	 	 	 
	PRO-VISION DEVELOPMENT CORPORATION	 	NEK-SEN Energy Partners	 	 
	 
	 	 	 	 	 	 	 	 
	/s/ Matthew Crouse
 

Matthew Crouse

	 	 	 	By:
	 	/s/ Gary Edelman
 
 
	 	 
	 

	 	 	 	Its:
	 	President	 	 

3exv10w12

 

EXHIBIT 10.12

January 20, 2006

Mr. Matt Crouse

NEKSEN Energy

205 South 8th

Sabetha, Kansas 66534

Preliminary Track Design (Ethanol Plant – Falls City, NE)

Dear Mr. Crouse:

Hanson-Wilson, Inc. (HWI) is pleased to present our proposal to perform preliminary track layout
for the above-mentioned project.

Schedule and Fee:

HWI could begin immediately upon a notice-to-proceed and a signed contract agreement. Upon
completion of an acceptable preliminary track layout, we can submit plans to the BSNF for approval.
Upon BNSF approval HWI would prepare a preliminary construction cost estimate for the track
portion of the project. Our lump sum fee for the services listed below is $3,400.00.

Additional Services Options:

HWI could add the services of preliminary design for the civil site and drainage for a total fee of
$4,800.00.

HWI could add the services of preliminary design for the civil site, drainage, and roadways and
pavement/parking for a total fee of $5,600.00.

     Our “Scope of Services” items include:

	 	Ø	 	Obtain rough digital ground model from Terraserver, inc. for design purposes and
earthwork estimating.
	 
	 	Ø	 	Work with NEKSEN energy on an acceptable preliminary track layout.
	 
	 	Ø	 	Submit acceptable preliminary track layout to BSNF for approval.
	 
	 	Ø	 	Prepare preliminary construction cost estimate for track portion of the project.

4015 S. 148th Street, Suite 101 n Omaha, Nebraska 68137 n 402-896-6100

Fax: 402-896-9300

Albuquerque,
NM n Colorado Springs, CO
n Chicago, IL
n Denver, CO
n Fort Worth, TX n 

Houston,
TX n Kansas City, MO n Los Angeles, CA

Omaha, NE n Orlando, FL n Peoria, IL n Phoenix, IL n Rockford, IL n Salina, KS n San Bernardino, CA

n Seattle, WA n Springfield, IL n Stockton, CA

 PRINTED ON RECYCLED PAPER

 

 

Deliverables:

	 	Ø	 	Electronic Color PDF of preliminary design
	 
	 	Ø	 	4 colored hard copies of preliminary design (1/2 size, full size, or both)
	 
	 	Ø	 	Electronic preliminary cost estimate (in xls format)

     Key Understandings:

	 	Ø	 	Track design and bridge design will utilize BNSF Technical Specifications for
Construction of Industry Track and BNSF Standard Bridge Specifications.
	 
	 	Ø	 	Permitting & Environmental issues are not included in this scope of work.
	 
	 	Ø	 	Scope of work does not include any geotechnical investigation.
	 
	 	Ø	 	Hydraulic & Hydrology studies for bridge design locations are not part of this
scope.
	 
	 	Ø	 	Coordination with Fagen engineering on civil & drainage design, roadways,
pavement, and plant layout/location will be necessary to complete the work.
	 
	 	Ø	 	This scope of work only includes fee for a “reasonable” number of iterations for
the preliminary track design. Moderate changes to the track layout are included in
our scope. Continues change requests beyond a “reasonable” amount may require more
fees.

Acceptance:

     NEKSEN Energy hereby accepts the proposal outlined above and does hereby engage Hanson-Wilson
to perform the Services described above, on the terms and conditions set forth in the forgoing
Letter Agreement. NEKSEN Energy accepts and agrees to the terms and conditions of the foregoing
Letter Agreement (including the terms and conditions set forth in the General Provisions attached
hereto.)

NEKSEN Energy

	 	 	 	 	 
	By:

Printed Name:

	 	/s/ Gary Edelman
 

Gary Edelman
	 	 
	Title:

	 	President	 	 

Date: 1/27/06

 

 

GENERAL PROVISIONS

     These General Provisions are attached to and made a part of the LETTER AGREEMENT, dated
January 20, 2006 between NEKSEN Energy (“CLIENT”) and HANSON-WILSON, INC. (“HANSON-WILSON”) in
respect of the Project described in the Letter Agreement. For purposes hereof, the Letter
Agreement, these General Provisions and any attachments to the Letter Agreement or these General
Provisions shall sometimes be collectively referred to as the “Agreement”. In consideration of the
mutual covenants contained in the Letter Agreement and these General Provisions, CLIENT and
HANSON-WILSON herein agree with respect of the performance of the Services (as described in the
foregoing by Letter Agreement), as follows:

SECTION 1: BASIC SERVICES OF HANSON-WILSON

     HANSON-WILSON shall provide CLIENT the professional services described in the Scope of
Services section of the Letter Agreement (“Basic Services”). HANSON-WILSON shall not be obligated
to perform any work or services which are not part of, or are in addition to, the Basic Services
(“Additional Services”). HANSON-WILSON shall be entitled to receive compensation for any
Additional Services by reimbursing HANSON-WILSON for the expenses it incurs in performing the
Additional Services and for the time spent in performing the Additional Services on the basis of
HANSON-WILSON Schedule of Rates and Expenses in effect at the time the Additional Services are
provided. HANSON-WILSON shall not be obligated to perform, provide, furnish or obtain any
Additional Services without the prior written authorization of CLIENT. “Basic Services” and
“Additional Services” are sometimes collectively referred to herein as “Services”.

SECTION 2: CLIENT’S RESPONSIBILITIES

     CLIENT will perform the duties identified in the Letter Agreement, if any, and in addition
will at all times cooperate with HANSON-WILSON in the performance of the Services and CLIENT shall
perform such other duties as are reasonable requested by HANSON-WILSON, from time to time, to
assist in the timely and efficient performance by HANSON-WILSON of the Services.

SECTION 3: PERIODS OF SERVICE

     3.1 Completion Date. If an anticipated date for the completion of the Basic Services is set
forth in the Schedule section of the Letter Agreement (the “Completion Date”), such a Completion
Date is estimated, but not guaranteed, to be the date that the Basic Services will be completed.
If the Completion Date is exceeded through no fault of HANSON-WILSON, all rates, measures and
compensation provided for under the Agreement shall be subject to equitable adjustment. The
Completion Date (and HANSON-WILSON obligation to complete the Basic Services by such date) is
subject to reasonable extensions for the performance of Additional Services, constructive changes
or other work and is subject to reasonable extensions for a Force Majeure Event.

     3.2 Force Majeure. For purposes hereof, a “Force Majeure Event” shall mean the occurrence of
a failure or delay due to circumstances beyond HANSON-WILSON control, including, without
limitation, acts of God, acts of public enemy, fires, floods, earthquakes, wars, civil
disturbances, sabotage, accidents, insurrection, blockages, embargoes, storms, explosions,
catastrophes, epidemics, damage to the Project, lack of access to Project, unavailable utilities
and power, water, labor disputes, CLIENT’s failure to timely perform its obligations under this
Agreement or other causes beyond HANSON-WILSON control.

SECTION 4: PAYMENTS TO HANSON-WILSON

	 	4.1	 	Monthly Invoices. HANSON-WILSON shall submit monthly statements for Basic and
Additional Services rendered and for reimbursable expenses incurred. CLIENT shall make
prompt monthly payments in response to HANSON-WILSON monthly statements. If CLIENT
fails to make any payment due HANSON-WILSON for services and expenses within thirty
(30) days after receipt of HANSON-WILSON statement therefore, HANSON-WILSON shall be
entitled interest on the unpaid amounts due HANSON-WILSON at the lessor of: i) 1.5% per
month; or ii) the highest rate of interest allowed under applicable law. The entire
unpaid balance due HANSON-WILSON shall bear said rate of interest from the thirtieth
day after CLIENT’s receipt of HANSON-WILSON statement, until the entire unpaid balance
has been paid to HANSON-WILSON. In addition to being entitled to interest,
HANSON-WILSON may, after giving seven (7) days written notice to CLIENT, suspend
services under this Agreement until HANSON-WILSON has been paid in full all mounts due
for Services, expenses, and charges.

     4.2 Payments after Termination. In the event of termination by CLIENT to HANSON-WILSON under
paragraph 5.1, HANSON-WILSON will be paid for Services rendered and expenses incurred through the
date of termination and HANSON-WILSON shall also be reimbursed for the charges of independent
professional associates and consultants employed by HANSON-WILSON to render Basic Services or
Additional Services and all reasonable demobilization costs incurred by HANSON-WILSON, including
any cancellation charges by independent professional associates, consultants and other performing
or furnishing Services on the Project through HANSON-WILSON, and HANSON-WILSON shall be paid for
all Additional Services performed and unpaid reimbursable expenses incurred through the date of the
termination.

SECTION 5: GENERAL CONSIDERATIONS

 

 

SECTION 5.1. Termination. The obligation to provide further services under this Agreement may be
terminated by either party upon seven (7) days’ written notice to the other party in the event of
substantial failure by the other party to perform in accordance with the terms hereof through no
fault of the terminating party.

SECTION 5.2. Resuse of Documents. All documents, drawings, sketches, studies, analysis,
information, schedules, estimates, reports and other items prepared or furnished by HANSON-WILSON
(or HANSON-WILSON independent professional associates and consultants) pursuant to this Agreement,
including, but not limited to Drawings and Specifications, are instruments of service in respect of
the Project and HANSON-WILSON shall retain an ownership and property interest therein whether or
not the Project is completed. Provided, however, that such documents, drawings, sketches, studies,
analysis, information, schedules, estimates, reports and other items are not intended or
represented to be suitable for reuse by CLIENT or others on extensions of the Project or on any
other project. Any reuse without written verification or adaptation by HANSON-WILSON for the
specific purpose intended will be at CLIENT’s sole risk and without liability or legal expose to
HANSON-WILSON, or to HANSON-WILSON independent professional associates or consultants, and CLIENT
does hereby, to the fullest extent permitted by law, indemnify and hold harmless HANSON-WILSON,
HANSON-WILSON officer, employees and agents and HANSON-WILSON independent professional associates
and consultants from all claims, suits, demands, damages, liabilities, losses, expenses and costs,
including but not limited to reasonable attorney’s fees and other costs of defense, arising out of
or resulting there from.

SECTION 5.3. Standard of Practice, Warranties. Services performed by the HANSON-WILSON under this
Agreement will be conducted in a manner consistent with the level of care, diligence and skill
ordinarily possessed and exercised by members of the profession currently practicing in the same
locality under similar conditions. Except as expressly set forth above, no other representations,
expressed or implied, and no warranty or guarantee is included in this Agreement, or in any
document, drawing, sketch, study, analysis, schedule, estimate, report, opinion, specification and
other item prepared or furnished by HANSON-WILSON (or HANSON-WILSON independent professional
associates and consultants) pursuant to this Agreement. HANSON-WILSON makes no representations,
covenants, warranties or guarantees, express or implied, other than those expressly set forth
herein. IMPLIED WARRANTIES OR MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE ARE
SPECIFICALLY EXCLUDED. The parties’ rights, liabilities, responsibilities and remedies with
respect to the Services, whether in contract or otherwise, shall be exclusively those expressly set
forth in this Agreement.

SECTION 5.4. Opinions of Cost and Schedule. Since HANSON-WILSON has no control over the cost of
labor, materials, equipment or services furnished by others, or over the resources provided by
others to meet construction or other Project schedules, or over the methods of others in
determining prices, or over competitive biding or market conditions. HANSON-WILSON opinions of
probable costs (including probable Total Project Costs and Construction Cost) and of Project
schedules shall be made on the basis of HANSON-WILSON experience and qualifications and represent
HANSON-WILSON best judgment as an experienced and qualified professional engineer, familiar with
the construction industry; but HANSON-WILSON cannot and does not guarantee that proposals, bids or
actual Project costs (including Total Project Costs or Construction Costs) will not vary from
opinions of probable cost prepared by HANSON-WILSON or that actual schedules will not vary from the
project schedules prepared by HANSON-WILSON.

SECTION 5.5 Limitation of Responsibility, Jobsite Safety/Techniques. HANSON-WILSON shall not have
control over or charge of and shall not be responsible for construction means, methods, techniques,
sequences or procedures, or for safety precautions and programs in connection with the Project or
any contractor, subcontractor, vendor or other Project participant, not under contact to
HANSON-WILSON (collectively the “Other Project Parties”). In addition, HANSON-WILSON shall not be
responsible for: i) the failure of any of the Other Project Parties to fulfill their respective
contractual responsibilities and obligations to CLIENT or to comply with federal, state or local
laws, rules, regulations or codes; ii) for the schedules of any of the Other Project Parties or the
failure of any of the Other Project Parties to carry out their work in accordance with their
respective agreements. HANSON-WILSON shall not have control over or charge of and shall not be
responsible for acts or omissions of the Other Project Parties, or their agents or employees, or of
any other persons performing portions of the work on the Project.

SECTION 5.6. Consequential Damages. To the fullest extent permitted by law, HANSON-WILSON shall
not, in any event, be liable to CLIENT for any special, indirect, incidental or consequential
damages, including, but not limited to, damages from delay, distribution, loss of product, loss of
use, loss of profits or revenue or increased cost of operation, the cost of capital or the cost of
purchased or replacement equipment, systems or power.

SECTION 5.7 Limitation of Liability. To the fullest extent permitted by law, HANSON-WILSON total
liability to CLIENT for all claims, losses, damages and expenses resulting or arising in any way
from the performance of the Services (including HANSON-WILSON indemnity obligations hereunder)
shall not exceed the total compensation received by HANSON-WILSON under this Agreement or the
limits of any professional liability insurance maintained by HANSON-WILSON, whichever is less.

SECTION 5.8 Survival. The terms and conditions of this Section 5 shall survive the termination of
this Agreement and/or the completion of the Services.

SECTION 6: SPECIAL PROVISIONS.

 

 

SECTION 6.1. Contract Documents. The Letter Agreement, together with these General Provisions and
with the Exhibits, schedules and other attachments identified in the Letter Agreement constitute
the entire agreement between CLIENT and HANSON-WILSON and supersede all prior written or oral
understandings. The Letter Agreement, these General Provisions and said Exhibits, schedules and
attachments may only be amended, supplemented, modified, or cancelled by a duly executed written
instrument.

SECTION 6.2. Hazardous Materials. Unless otherwise provided in this Agreement, HANSON-WILSON shall
have no responsibility for the discovery, presence, handling, removal or disposal of or exposure of
persons to hazardous materials in any form at the Project site. However, HANSON-WILSON shall
report to CLIENT the presence and location of any hazardous material which it notices or which an
engineer of similar skill and experience should have noticed.

     6.3 Disputes; Attorneys Fees. In the event a dispute arises between HANSON-WILSON and CLIENT
regarding the application or interpretation of any provision of this Agreement, or quality of
Services by HANSON-WILSON, the aggrieved party shall promptly notify the other party to this
Agreement of the dispute, but in no event more than 20 days after such dispute arises. If the
parties fail to resolve the dispute within 20 days after receipt of such notice, each party shall,
within five days thereafter, proceed to non-binding mediation, with each party to bear its own
costs and attorneys’ fees and the parties shall share equally the cost of the mediator. In the
event that the mediation is unsuccessful, the aggrieved party may elect to litigate its dispute
with the other party. All disputes shall be governed by the laws of the State of Missouri and the
jurisdiction and venue for litigation between the parties shall be solely and exclusively in
Jackson County, Missouri, or the United States District Court for the Western District of Missouri.
In the even that either party hereto employs an attorney to enforce any provision of this
Agreement or to collect damages for default or breach of this Agreement, or pursue claims in
litigation or arbitration, the prevailing party in any such action shall be entitled to recover
from the other such attorneys’ fees and costs of collection as the prevailing party may expend or
incur with respect thereto. In the event that a settlement is reached between the parties before a
final decision in any such litigation or arbitration, then neither party shall be entitled to
recover its attorneys fees or costs from the other and neither party shall be responsible for the
other party’s attorney’s fees or costs, unless otherwise agreed by the parties.

     6.4 General. This Agreement shall be governed by and interpreted in accordance with the laws
of Missouri. The Agreement shall not be assignable by CLIENT without the prior written consent of
HANSON-WILSON. This Agreement shall be binding upon and shall inure to the benefit of the
HANSON-WILSON and CLIENT’s respective successors and assigns. In the event that any portion or all
of this Agreement is held to be void or unenforceable, the parties agree to negotiate in good faith
to reach an equitable agreement which shall affect the intent of the parties as set forth in this
Agreement. No failure by either party to insist on performance of any term, condition, or
instruction, or to exercise any right or privilege included in this Agreement, and no waiver of any
breach shall constitute a waiver of any other or subsequent term, condition, instruction, breach,
right or privilege. The parties acknowledge and agree that the terms and conditions of this
Agreement, including but not limited to those relating to allocations and assumptions of, release
from, exclusions against and limitations of liability, have been freely and fairly negotiated.
Each party acknowledges that in executing this Agreement they have relied solely on their own
judgment, belief, and knowledge, and such advice as they may have received from their own counsel,
and they have not been influenced by any representation or statements made by any other party or
its counsel. No provision in this Agreement is to be interpreted for or against any party because
that party or its counsel drafted such provision.

General. This Agreement shall be governed by and interpreted in accordance with the laws of
Nebraska. The Agreement shall not be assignable by CLIENT without the prior written consent
of HANSON-WILSON. This Agreement shall be binding upon and shall inure to the benefit of
the HANSON-WILSON and CLIENT’s respective successors and assigns. In the even that any
portion or all of this Agreement is held to be void or unenforceable, the parties agree to
negotiate in good faith to reach an equitable agreement which shall affect the intent of the
parties as set forth in this Agreement. No failure by either party to insist on performance
of any term, condition, or instruction, or to exercise any right or privilege included in
this Agreement, and no waiver of any breach shall constitute a waiver of any other or
subsequent term, condition, instruction, breach, right or privilege. The parties
acknowledge and agree that the terms and conditions of this Agreement, including but not
limited to those relating to allocations and assumptions of, release from, exclusions
against and limitations of liability, have been freely and fairly negotiated. Each party
acknowledges that in executing this Agreement they have relied solely on their own
judgement, belief, and knowledge, any such advice as they may have received from their own
counsel, and they have not been influenced by and representation or statements made by any
other party or its counsel. No provision in this Agreement is to be interpreted for or
against any party because that party or its counsel drafted such provision.

	 	 	 
	Accepted:
/s/ GE           CLIENT’s Initials

	 	/s/ JL                     HANSON-WILSON Initials

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00104-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00104-of-00352.parquet"}]]