Document:

Lease dated October 27, 2003

 EXHIBIT 10.2 
  
 * * * * * * * * * * * * * * * * * * * * 
  
 LEASE 
  
 RIO ROBLES TECHNOLOGY CENTRE 
  
 * * * * * * * * * * * * * * * * * * * * 
  
 Between 
  
 PERICOM SEMICONDUCTOR CORPORATION 
 (Tenant) 
  
 and 
  
 CARRAMERICA REALTY CORPORATION 
 (Landlord) 

 TABLE OF CONTENTS 
  

	 	  	Page

	[Table of Contents appears at the end of the Lease]	  	 

  

 i 

 LEASE 
  
 THIS LEASE (the “Lease”) is dated as of October 27, 2003 (for reference purposes only) between CarrAmerica Realty Corporation, a Maryland
corporation (“Landlord”) and the Tenant as named in the schedule below (the “Schedule”). The term “Project” means the seven (7) buildings, the land appurtenant thereto (“Land”), and
other improvements located thereon commonly known as “Rio Robles Technology Centre”, located in San Jose, California. The “Premises” means that portion of the Project leased to Tenant and described in the Schedule and
outlined on Exhibit A. The building in which the Premises are located shall be referred to herein as the “Building”. The Schedule is an integral part of this Lease. Terms defined in this Schedule shall have the same meaning
throughout the Lease. 
  
 SCHEDULE 
  

	 	1.	 	Tenant: Pericom Semiconductor Corporation, a California corporation 

  

	 	2.	 	Premises: The entirety of “Building G”, commonly known as 3545 North First Street, San Jose, California 

  

	 	3.	 	Intentionally omitted 

  

	 	4.	 	Rentable Square Footage of the Premises: Approximately 76,145 rentable square feet 

  

	 	5.	 	Tenant’s Proportionate Share: 100% 

  

	 	6.	 	Lease Deposit: Security Deposit equal to One Hundred Nineteen Thousand Nine Hundred Sixty-Nine and 08/100 Dollars ($119,969.08). 

  

	 	7.	 	Permitted Use: General office and research and development and engineering of semiconductor-related products 

  

	 	8.	 	Tenant’s Real Estate Broker for this Lease: Colliers International– Jim Abarta, Phil Arnautou 

  

	 	9.	 	Landlord’s Real Estate Broker for this Lease: None 

  

	 	10.	 	Tenant Improvements, if any: See Section 3.A and the Tenant Improvement Agreement attached hereto as Exhibit C 

  

	 	11.	 	Commencement Date: December 29, 2003 (but see Section 1.A(1))  

  

	 	    	 	Rent Commencement Date: The date that is five (5) months following the Commencement Date 

  

	 	12.	 	Term/Termination Date: The Term of this Lease shall be for ten (10) years commencing on the Commencement Date and expiring on the calendar day preceding the tenth (10th)
anniversary of the Commencement Date; provided, 

  
  

 ii 

	 	 
however, that if the Commencement Date shall occur on a date other than the first day of a calendar month, the Termination Date shall be the last day of the
calendar month in which the tenth (10th) anniversary of the Commencement Date occurs. 

  

	 	13.	 	Parking Stalls: 289 unassigned stalls 

  

	 	14.	 	Base Rent:  

  

	 Period

	  	Monthly
Base Rent

	    	Annualized
Base Rent

	 Commencement Date to the Rent Commencement Date
	  	$	0.00	    	$	0.00
	 Rent Commencement Date through the 12th full calendar month of the Term
	  	$	72,337.75	    	$	868,053.00
	 13th through 24th full calendar months of the Term
	  	$	74,507.88	    	$	894,094.56
	 25th through 36th full calendar months of the Term
	  	$	76,743.12	    	$	920,917.44
	 37th through 48th full calendar months of the Term
	  	$	79,045.41	    	$	948,544.92
	 49th through 60th full calendar months of the Term
	  	$	81,416.77	    	$	977,001.24
	 61st through 72nd full calendar months of the Term
	  	$	83,859.28	    	$	1,006,311.36
	 73rd through 84th full calendar months of the Term
	  	$	86,375.06	    	$	1,036,500.72
	 85th through 96th full calendar months of the Term
	  	$	88,966.31	    	$	1,067,595.72
	 97th through 108th full calendar months of the Term
	  	$	91,635.30	    	$	1,099,623.60
	 109th full calendar month of the Term through the Termination Date
	  	$	94,384.36	    	$	1,132,612.28

  

	 	15.	 	Renewal Option: Two (2) options to extend for a period of five (5) years each 

  

	 	16.	 	Right of First Offer: To lease the buildings commonly known as 30 Rio Robles Drive (Building F) and 50 Rio Robles Drive (Building E), San Jose, California

  
 Exhibit A - PLAN OF THE PREMISES 
 Exhibit A-1 - PLAN OF FIRST OFFER SPACE 
  

 iii 

 Exhibit B - RULES AND REGULATIONS 
 Exhibit C - TENANT IMPROVEMENT AGREEMENT 
 Exhibit C-1 - APPROVED SPACE PLAN 
 Exhibit D - COMMENCEMENT DATE CONFIRMATION 

Exhibit E - ENVIRONMENTAL QUESTIONNAIRE 
  
  

 iv 

 1. LEASE AGREEMENT. On the terms stated in this Lease, Landlord leases the Premises to Tenant, and
Tenant leases the Premises from Landlord, for the Term beginning on the Commencement Date and ending on the Termination Date, unless extended or sooner terminated pursuant to this Lease. 
  
 A. Commencement Date. 
  
 1. The commencement date (“Commencement Date”) for this Lease is the date set forth in the Schedule; provided, however, that (a) if the
Substantial Completion Date fails to occur on or before December 29, 2003 for any reason, (i) this Lease shall not be void or voidable by either party, (ii) Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and (iii)
the Commencement Date shall be revised to mean the Substantial Completion Date; and (b) if Tenant commences business operations in any portion of the Premises prior to the Commencement Date, the Commencement Date shall be deemed to have occurred on
the date Tenant commences business operations in the Premises. Notwithstanding the foregoing, if Landlord is delayed in completing Landlord’s Work (as defined in the Tenant Improvement Agreement attached hereto as Exhibit C) or in
delivering possession of the Premises to Tenant as a result of any Tenant Delay (as defined in Section 4 of Exhibit C), the Substantial Completion Date shall be deemed to have occurred on the date the Substantial Completion Date would have
occurred in the absence of such Tenant Delay, as reasonably determined by Landlord or Landlord’s architect. Tenant shall be responsible for and shall pay any additional costs and expenses incurred by Landlord in connection with the completion
of Landlord’s Work as a result of any Tenant Delay. Notwithstanding the foregoing, if the Substantial Completion Date does not occur on or before May 31, 2004, Tenant shall have the right to terminate this Lease by delivery of written notice to
Landlord no later than June 15, 2004. 
  
 2. If the Commencement
Date is other than December 29, 2003, then Landlord shall prepare and deliver to Tenant a Commencement Date Confirmation substantially in the form attached hereto as Exhibit D that sets forth both the Commencement Date and Termination Date
for this Lease. Tenant shall execute the Commencement Date Confirmation and deliver the executed original of the same to Landlord within three (3) business days after Tenant’s receipt thereof. Provided that Tenant has not objected in writing
within such three (3) business day period to the Commencement Date or Termination Date set forth in the Commencement Date Confirmation, Tenant’s failure to timely execute and return the Commencement Date Confirmation document to Landlord shall
be conclusive evidence of Tenant’s agreement with the information as set forth therein. 
  
 3. This Lease shall be a binding contractual obligation effective upon execution and delivery hereof by Landlord and Tenant, notwithstanding the later commencement of the Lease Term. 
  
 B. Termination Date. The termination date (“Termination
Date”) of this Lease is the date set forth in the Schedule, unless the Term is extended pursuant to Section 31 below. 
  

 1 

 C. Early Occupancy. During the period commencing approximately thirty (30) days prior to the
scheduled Commencement Date (or any other date agreed to by Landlord and Tenant in writing) and ending on the Commencement Date (the “Early Occupancy Period”), Tenant shall be permitted to enter the Premises for the purpose of
installing certain trade fixtures, cabling, furniture and other personal property therein, provided that (1) Tenant’s early entry does not interfere with Landlord’s Work, (2) prior to Tenant’s entry in the Premises, Tenant shall
furnish to Landlord certificates of insurance satisfactory to Landlord evidencing Tenant’s compliance with the requirements of Section 8.C below, and (3) Tenant shall comply with the requirements of Section 5 below. Tenant’s occupancy of
the Premises during the Early Occupancy Period shall be subject to all of the terms, covenants and conditions of this Lease, except that Landlord agrees that Tenant’s obligation to pay Base Rent, Operating Cost Share Rent and Tax Share Rent (as
such terms are defined in Sections 2.A(1) through 2.A(3) below) during the Early Occupancy Period shall be waived. To the extent caused by Tenant’s early entry, any delay in Landlord’s Work shall constitute a Tenant Delay hereunder.

  
 2. RENT. 
  
 A. Types of Rent. Tenant shall pay the following Rent in the form of
a check to Landlord at the following address: 
  
 CarrAmerica Realty Corporation 
 t/a Rio Robles Technology Centre 
 P.O. Box 642922 
 Pittsburgh, PA 15264-2922 
  
 or by wire transfer as follows: 

 

	 Account Name:
	  	 CarrAmerica Realty Corporation

	 	  	 t/a Rio Robles Technology Centre

	 Bank Name:
	  	 PNC Bank

	 Transit Number:
	  	 043-000-096

	 Account Number:
	  	 1004339188

	 Notification:
	  	 Lease Administration (CarrAmerica Realty
 Corporation re Pericom Semiconductor
 Corporation)

	 Telephone:
	  	(202) 729-3852

  
 or in such other manner as Landlord
may notify Tenant. 
  
 1. Base Rent in monthly
installments in advance in the amounts set forth in the Schedule, commencing on the Rent Commencement Date and continuing on the first day of each calendar month thereafter; provided, however, that if the Rent Commencement Date is a day other than
the first day of a calendar month, then the Partial Lease Month Rent (as defined below) shall be payable by Tenant on the first day of the calendar month immediately following the Rent Commencement Date. The “Partial Lease Month
Rent” means the Base Rent for the partial month in which the Rent Commencement Date occurs, which shall be calculated on a per diem basis at the rate of Two Thousand Four Hundred Eleven and 26/100 Dollars ($2,411.26) per day for the number
of days of such month from and including the Rent Commencement Date. 
  

 2 

 2. Operating Cost Share Rent equal to the following, to be paid by Tenant monthly on or before
the first day of each month in advance in an estimated amount: (a) Tenant’s Proportionate Share (as set forth in the Schedule) of Operating Costs for the applicable Fiscal Year (as defined in Section 2.C(5) below), plus (b) a monthly management
fee equal to two and one-half percent (2.5%) of (i) the Base Rent payable for such month, plus (ii) the amounts payable by Tenant pursuant to clause (a) of this Subsection and pursuant to Section 2.A(3) below. The definition of Operating Costs and
the method for billing and payment of Operating Cost Share Rent are set forth in Sections 2.B, 2.C and 2.D. 
  
 3. Tax Share Rent equal to Tenant’s Proportionate Share of Taxes for the applicable Fiscal Year, paid monthly in advance in an estimated
amount. A definition of Taxes and the method for billing and payment of Tax Share Rent are set forth in Sections 2.B, 2.C and 2.D. 
  
 As used in this Lease, the term “Rent” means Base Rent, Operating Cost Share Rent, Tax Share Rent and all other costs, expenses,
liabilities, and amounts which Tenant is required to pay under this Lease (“Additional Rent”), including any interest for late payment. Tenant’s agreement to pay Rent is an independent covenant, with no right of setoff,
deduction or counterclaim of any kind. 
  
 B. Payment of
Operating Cost Share Rent and Tax Share Rent. 
  

	 	1.	 	Payment of Estimated Operating Cost Share Rent and Tax Share Rent. 

  
 (a) Before the Commencement Date and on or before April 1 of each succeeding Fiscal Year, or as soon as reasonably possible thereafter, Landlord shall
give Tenant notice of its estimate of the payments to be made pursuant to Sections 2.A(2) and 2.A(3) above for such Fiscal Year. Landlord may revise these estimates by written notice to Tenant whenever it obtains more accurate information, such as
the final real estate tax assessment or tax rate for the Project, in which event subsequent monthly payments by Tenant for such Fiscal Year shall be based upon such revised estimate. 
  
 (b) Within twenty (20) days after receiving Landlord’s notice regarding the original or revised estimate of the
monthly payments to be made pursuant to Sections 2.A(2) and 2.A(3) above for a particular Fiscal Year, Tenant shall pay Landlord an amount equal to the product of such estimated monthly payments (as set forth in Landlord’s notice), multiplied
by the number of months that have elapsed in the applicable Fiscal Year to the date of such payment including the current month, minus any payments on account thereof previously made by Tenant for the months elapsed. On the first day of each month
thereafter, Tenant shall pay Landlord the estimated monthly payments as set forth in Landlord’s most recent notice, until a new estimate becomes applicable. 
  
 2. Correction of Operating Cost Share Rent and Tax Share Rent. Within one hundred fifty (150) days after the close
of each Fiscal Year or as soon as reasonably 

  

 3 

 
practicable thereafter, Landlord shall deliver to Tenant a statement of (a) Operating Costs and Taxes for such Fiscal Year, and (b) the payments made by
Tenant under Section 2.B(1) above for such Fiscal Year (the “Annual Expense Statement”). If, on the basis of any Annual Expense Statement, Tenant owes an amount that is less than the estimated payments previously made by Tenant for
the applicable Fiscal Year, Landlord shall either promptly refund the amount of the overpayment to Tenant or, if this Lease is still in effect, credit such excess against Tenant’s subsequent obligations to pay Operating Costs and Taxes. If, on
the basis of any Annual Expense Statement, Tenant owes an amount that is more than the estimated payments previously made by Tenant for the applicable Fiscal Year, Tenant shall pay the deficiency to Landlord within thirty (30) days after
Landlord’s delivery of such Annual Expense Statement to Tenant. 
  
 C. Definitions. 
  
 1. Included Operating
Costs. 
  
 (a) “Operating Costs” means any
expenses, costs and disbursements of any kind other than Taxes, paid or incurred by Landlord in connection with the management, maintenance, operation, insurance (including the related deductibles), repair, ownership and replacement of the Project
and of the personal property, fixtures, machinery, equipment, systems and apparatus used in connection therewith, including, without limitation, (i) the cost of providing those services required to be furnished by Landlord under this Lease, and (ii)
the cost of all electricity, water, gas, sewers, oil and other utilities (collectively, “Utilities”), including any surcharges imposed, serving the Project or any part thereof (but excluding the cost of Utilities directly billed to
Tenant or other tenants in the Project), and any amounts, taxes, charges, surcharges, assessments or impositions levied, assessed or imposed upon the Project or any part thereof, or upon Tenant’s use and occupancy thereof, as a result of any
rationing of Utilities services or restriction on the use of Utilities affecting the Project or any part thereof. Operating Costs shall also include the costs of any capital improvements made which are intended to reduce Operating Costs or improve
safety, and those made to keep the Project in compliance with Governmental Requirements (as defined in Section 5.A(3)(c) below) applicable from time to time or to repair or replace existing capital improvements, facilities and equipment within the
Project, such as the roof membrane and resurfacing of the parking areas (collectively, “Included Capital Items”); provided, that the costs of any Included Capital Item shall be amortized by Landlord, together with an amount equal to
interest at ten percent (10%) per annum, over the estimated useful life of such item, which shall be estimated in Landlord’s reasonable determination, and such amortized costs are only included in Operating Costs for that portion of the useful
life of the Included Capital Item which falls within the Term, unless the cost of the Included Capital Item is less than Ten Thousand Dollars ($10,000) in which case it shall be expensed in the year in which it was incurred. 
  
 (b) Operating Costs shall include (i) all Operating Costs fairly allocable
to the Building, and (ii) a proportionate share (based on the gross rentable area of the Building, i.e., 76,145 rentable square feet, as a percentage of the gross rentable area of all of the buildings in the Project, i.e., 368,178 rentable square
feet) of all Operating Costs which relate to the Project in general and are not fairly allocable to any one building in the Project. 
  

 4 

 (c) If the Project is not fully occupied during any portion of any Fiscal Year, Landlord may adjust (an
“Equitable Adjustment”) Operating Costs to equal what would have been incurred by Landlord had the Project been fully occupied. The Equitable Adjustment shall apply only to Operating Costs which are variable and therefore increase
as occupancy of the Project increases. Landlord may incorporate the Equitable Adjustment in its estimates of Operating Costs. 
  
 (d) If any tenant of the Project contracts directly with Landlord or a third party for any Utilities or services for which Tenant pays Landlord pursuant
to Section 2.A(2) above, the total costs of such Utilities or services for the Project shall be “grossed up” to reflect what those costs would have been had such tenant(s) not directly contracted for such Utilities or services. 

 
 2. Excluded Operating Costs. Operating Costs shall not include:

  

	 	(a)	 	costs of installing leasehold improvements for tenants or occupants or prospective tenants or occupants of the Project; 

  

	 	(b)	 	costs of capital improvements other than Included Capital Items; 

  

	 	(c)	 	interest and principal payments on mortgages or any other debt costs (except as provided in Section 2.C(1) above with regard to Included Capital Items), or rental payments on any
ground lease of the Project; 

  

	 	(d)	 	real estate brokers’ leasing commissions; 

  

	 	(e)	 	legal fees, space planner fees and advertising expenses incurred with regard to leasing the Project or portions thereof; 

  

	 	(f)	 	any cost or expenditure for which Landlord is reimbursed, by insurance proceeds or otherwise, except by Operating Cost Share Rent; 

  

	 	(g)	 	the cost of any service furnished to any office tenant of the Project which Landlord does not make available to Tenant; 

  

	 	(h)	 	depreciation (except on any Included Capital Items); 

  

	 	(i)	 	net income (except Rent Tax), capital, stock, succession, transfer, franchise, gift, estate or inheritance tax imposed upon Landlord, except to the extent imposed in lieu of all or
any part of Taxes; 

  

 5 

	 	(j)	 	legal and auditing fees incurred for the benefit of Landlord such as, but not limited to, collecting delinquent rents, preparing tax returns and other financial statements, and
audits other than those incurred in connection with the preparation of reports required pursuant to Section 2.B above; 

  

	 	(k)	 	the wages of any employee for services not related directly to the management, maintenance, operation and repair of the Project including executive salaries or salaries of service
personnel to the extent that such executives or service personnel perform services other than in connection with the management, operation, repair or maintenance of the Project; 

  

	 	(l)	 	fines, penalties and interest incurred by Landlord for late payment by Landlord or violations of law; 

  

	 	(m)	 	the cost of capital expenditures to correct violations of the Governmental Requirements (including the ADA) existing in the common areas of the Project as of the Commencement Date
based on the current interpretation of such Governmental Requirements (including the ADA) by applicable governmental authority(ies) as of the Commencement Date (it being understood that all other costs to bring the Project into compliance with
Governmental Requirements [including the ADA] shall be Operating Costs, except for compliance costs that are the responsibility of Tenant pursuant to Sections 7.A and 7.B below) or Landlord pursuant to Section 7.A; 

  

	 	(n)	 	the cost of abatement or removal of Hazardous Substances in, on, or about the Project; provided, however, that the costs of routine monitoring of and testing for Hazardous
Substances in, on, or about the Project shall be an Operating Cost; and 

  

	 	(o)	 	Reserves for bad debts or for future improvements, repairs, additions, etc. 

  
 3. Taxes. 
  
 (a) “Taxes” means any and all taxes, assessments and charges of any kind, general or special, ordinary or extraordinary, levied against
the Project, which Landlord shall pay or become obligated to pay in connection with the ownership, leasing, renting, management, use, occupancy, control or operation of the Project or of the personal property, fixtures, machinery, equipment, systems
and apparatus used in connection therewith. 
  

 6 

 
Taxes shall include real estate taxes, personal property taxes, sewer rents, water rents, special or general assessments, transit taxes, ad valorem taxes,
and any tax levied on the rents hereunder or the interest of Landlord under this Lease (the “Rent Tax”). Taxes shall also include all fees and other costs and expenses paid by Landlord in reviewing any Taxes and in seeking a refund
or reduction of any Taxes, whether or not the Landlord is ultimately successful. Taxes shall also include any assessments or fees paid to any business park owners association, or similar entity, which are imposed against the Project pursuant to any
Covenants, Conditions and Restrictions (“CC&R’s”) recorded against the Project and any installments of principal and interest required to pay any existing or future general or special assessments for public improvements, services
or benefits, and any increases resulting from reassessments imposed in connection with any change in ownership or new construction. 
  
 (b) Taxes shall include (i) all Taxes fairly allocable to the Building, and (ii) a proportionate share (based on the gross rentable area of the Building,
i.e., 76,145 rentable square feet, as a percentage of the gross rentable area of all of the buildings in the Project, i.e., 368,178 rentable square feet) of all Taxes which relate to the Project in general and are not fairly allocable to any one
building in the Project. 
  
 (c) For any year, the amount to be
included in Taxes (i) from taxes or assessments payable in installments, shall be the amount of the installments (with any interest, if any) due and payable during such year, and (ii) from all other Taxes, shall at Landlord’s election be the
amount accrued, assessed, or otherwise imposed for such year or the amount due and payable in such year. Any refund or other adjustment to any Taxes by the taxing authority, shall apply during the year in which the adjustment is made. Taxes shall
not include any (i) net income (except Rent Tax), capital, stock, succession, transfer, franchise, gift, estate or inheritance tax, except to the extent that such tax shall be imposed in lieu of any portion of Taxes, or (ii) any tax, levy,
assessment, charge or surcharge imposed as a direct result of contamination of the Project by any Hazardous Substances prior to the Commencement Date, as opposed to the imposition of such a charge on a more general basis. 
  
 4. Intentionally omitted. 
  
 5. Fiscal Year. “Fiscal Year” means each calendar
year during which any portion of the Term occurs (e.g., the first Fiscal Year shall be the calendar year during which the Commencement Date occurs). 
  
 D. Computation of Base Rent and Rent Adjustments. 
  
 1. Prorations. If the size of the Premises increases or decreases, then in each such event, the Base Rent, Operating Cost Share Rent and Tax Share
Rent shall be equitably adjusted to reflect such event on a basis determined by Landlord to be consistent with the principles underlying the provisions of this Section 2. If the Term commences on a date other than the first day of a calendar month
or terminates on a date other than the last day of a calendar month, the Rent for such partial months shall be prorated to the actual number of days the Lease is in effect for said partial months. 
  

 7 

 2. Interest Rate. Any sum due from Tenant to Landlord not paid when due shall bear interest from
the date due until paid at the lesser of ten percent (10%) per annum or the maximum rate permitted by law (the “Interest Rate”). 
  
 3. Rent Adjustments. The square footage of the Premises, the Building and all of the buildings in the Project as set forth in the Schedule and in
Section 3.C(1) are conclusively deemed to be the actual square footage thereof, without regard to any subsequent remeasurement thereof. If any Operating Cost paid in one Fiscal Year relates to more than one Fiscal Year, Landlord may proportionately
allocate such Operating Cost among the related Fiscal Years. 
  
 4. Books and Records. Landlord shall maintain books and records reflecting the Operating Costs and Taxes in accordance with sound accounting and management practices. Tenant and a certified public accountant working on a
non-contingency fee basis shall have the right to inspect Landlord’s records at Landlord’s applicable local office or other location designated by Landlord upon at least seventy-two (72) hours’ prior notice during normal business
hours during the twelve (12) months following Landlord’s delivery of the Annual Expense Statement to Tenant. The results of any such inspection shall be kept strictly confidential by Tenant and its agents, and Tenant and its certified public
accountant must agree, in their contract for such services, to such confidentiality restrictions and shall specifically agree that the results shall not be made available to any other tenant of the Project (and in connection with the foregoing,
prior to exercising its rights hereunder, Tenant and its agents shall sign a confidentiality agreement acceptable to Landlord). Unless Tenant sends to Landlord any written exception to an Annual Expense Statement within said twelve (12) month
period, such Annual Expense Statement shall be deemed final and accepted by Tenant and Tenant waives any other rights pursuant to applicable law to inspect Landlord’s books and records and/or to contest the amount Operating Costs and/or Taxes
due hereunder. Tenant shall pay the amount shown on any Annual Expense Statement in the manner prescribed in this Lease, whether or not Tenant takes any such written exception, without any prejudice to such exception. If Tenant makes a timely
exception, Landlord shall cause an independent certified public accountant to issue a final and conclusive resolution of Tenant’s exception. If, according to such accountant, Landlord’s original determination of annual Operating Costs and
Taxes overstated the amounts thereof, in the aggregate, by five percent (5%) or less, then Tenant shall pay the cost of the certification, and if, according to such certification, Landlord’s original determination of annual Operating Costs and
Taxes overstated the amounts thereof, in the aggregate, by more than five percent (5%), then Landlord shall pay the cost of the certification. Further, in the case of an understatement, Tenant shall pay to Landlord the deficiency in Tenant’s
payment of Operating Costs and Taxes within twenty (20) days following Tenant’s receipt of such certification. In the case of an overstatement, Landlord shall either promptly refund the amount of Tenant’s overpayment of Operating Costs and
Taxes or, if this Lease is still in effect, credit such overpayment against Tenant’s subsequent obligations to pay Operating Costs and Taxes. 
  
 5. Miscellaneous. So long as Tenant is in monetary default of any obligation under this Lease, Landlord shall not be obligated to refund any
amount to Tenant. If this Lease is terminated for any reason prior to the annual determination of Operating Cost Share Rent or Tax Share Rent, either party shall pay the full amount due to the other within fifteen (15) days after Landlord’s
notice to Tenant of the amount when it is determined. Landlord may commingle any payments made with respect to Operating Cost Share Rent and Tax Share Rent, without payment of interest. 
  

 8 

 E. Intentionally omitted. 
  
 3. PREPARATION AND CONDITION OF PREMISES; TENANT’S POSSESSION; REPAIRS AND MAINTENANCE. 
  
 A. Condition of Premises. Except for Landlord’s Work, Landlord
is leasing the Premises to Tenant “as is”, without any obligation to alter, remodel, improve, repair or decorate any part of the Premises and without any express or implied representations or warranties of any kind., including, without
limitation, any representation or warranty regarding the condition of the Premises, the Building or the Project or the suitability of any of the foregoing for the conduct of Tenant’s business; provided, however, that (1) Landlord shall deliver
all Building Systems (as defined in Section 5.B below) in good working condition on the Commencement Date, (2) Landlord shall repair, at no expense to Tenant, (a) any defects in the Building Systems (other than the HVAC system) that are noted by
Tenant in writing to Landlord within one hundred twenty (120) days following the Commencement Date and (b) any defects in the HVAC system that are noted by Tenant in writing to Landlord within two hundred ten (210) days following the Commencement
Date, and (3) Landlord shall cause Landlord’s Work to be completed in compliance with all applicable Governmental Requirements. 
  
 B. Tenant’s Possession. Tenant’s taking possession of any portion of the Premises for the purpose of conducting business shall be
conclusive evidence that the Premises were in good order, repair and condition, subject, however, to any punch-list items and/or defects as described in Section 3.A above. 
  
 C. Repairs and Maintenance. 
  
 1. Tenant’s Obligations. Except to the extent of Landlord’s obligations under Section 3.C(2) below or
except as provided in Section 9 below, Tenant shall, throughout the Term at its expense, make all repairs necessary to keep the Premises, including Building Systems, Tenant’s fixtures and personal property, in good order, condition and repair
and in compliance with all applicable Governmental Requirements. Tenant’s repair, maintenance and replacement obligations shall be performed within any reasonable period of time specified by Landlord under the supervision and subject to the
prior approval of Landlord. Tenant’s repair, maintenance and replacement obligations shall include, without limitation, all plumbing and sewage facilities within the Premises, fixtures, interior walls and ceiling, interior floors, windows
(including the repairing, resealing, cleaning and replacing of both interior and exterior windows), doors, entrances, plate glass, showcases, skylights, all electrical facilities and equipment, including lighting fixtures, lamps, fans and any
exhaust equipment and systems, electrical motors and all other appliances and equipment of every kind and nature located in, upon or about the Premises. Tenant shall also be responsible for all pest control within the Premises, and for all trash
removal and disposal from the Premises. Tenant shall obtain HVAC systems preventive maintenance contracts with quarterly service in accordance with manufacturer recommendations, which shall be subject to the reasonable prior written approval of
Landlord and paid for by Tenant, and which shall provide for and include replacement of filters, oiling and lubricating of 

  

 9 

 
machinery, parts replacement, adjustment of drive belts, oil changes and other preventive maintenance, including annual maintenance of duct work, interior
unit drains and caulking of sheet metal, and recaulking of jacks and vents on an annual basis. Tenant shall have the benefit of all warranties available to Landlord regarding the Building Systems. Alternatively, upon prior written notice to Tenant,
Landlord may elect to perform all or some of the foregoing repairs and maintenance itself, at Tenant’s expense, to the Building Systems. If Tenant fails to perform its obligations under this Section, Landlord, after notice and expiration of any
applicable cure period, may perform such repairs or maintenance itself at Tenant’s expense; provided, however, that in the event of an emergency, Landlord may immediately perform such repairs or maintenance without notice. At the expiration or
earlier termination of this Lease, or Tenant’s right to possession, Tenant shall return the Premises to Landlord in the condition required under Section 14 below. 
  
 2. Landlord’s Obligations. Except as otherwise provided in Section 9 below, Landlord agrees to make all
necessary repairs to the following, subject to inclusion of the costs thereof in Operating Costs: (a) the roof membrane and (b) the common areas of the Project, and to maintain the same in reasonably good order and condition; provided, however, that
subject to the provisions of Section 8.F below, any damage arising from the acts of Tenant or any Tenant Parties (as defined in Section 8.B(1) below) shall be repaired by Landlord at Tenant’s sole expense, and Tenant shall pay Landlord, on
demand, the cost of any such repair. Landlord may also, but shall not be required to, enter the Premises at all reasonable times to make such repairs, alterations, improvements or additions to the Premises or to the Project or to any equipment
located in the Project as Landlord shall desire or deem necessary or as Landlord may be required to do by governmental or quasi-governmental authority or court order or decree. The cost of any repairs made by Landlord on account of Tenant’s
default, or on account of the misuse or neglect by Tenant or any Tenant Parties anywhere in the Project, shall constitute Additional Rent payable by Tenant on demand. As a condition precedent to all of Landlord’s repair and maintenance
obligations under this Lease, Tenant must have notified Landlord of the need of such repairs or maintenance. Tenant hereby waives any and all rights under and benefits of subsection 1 of Section 1932 and Sections 1941 and 1942 of the California
Civil Code and any similar or successor law, statute or ordinance now or hereafter in effect regarding Tenant’s right to make repairs and deduct the cost of such repairs from the Rent due under this Lease. Except as provided in Section 9 below,
Landlord agrees to make all necessary repairs to the following, at Landlord’s sole cost and expense: the structural parts of the Building, which structural parts include only the foundation and subflooring of the Building and the structural
condition of the roof (excluding the roof membrane) and the exterior and interior load-bearing walls of the Building (but excluding the interior surfaces of exterior walls and exterior and interior of all windows, doors, ceiling and plate glass,
which shall be maintained and repaired by Tenant). 
  
 4.
SERVICES AND UTILITIES. Tenant shall be responsible for procuring all services and Utilities necessary for the Permitted Use in the Premises, and shall promptly pay, as the same become due, all charges for all Utilities, materials and
services furnished directly to or used by Tenant on or about the Premises during the Term, including, without limitation, (i) meter, use and/or connection fees, hook-up fees, or standby fees, and (ii) penalties for discontinued interrupted service.
If any utility service is not separately metered to the Premises, then Tenant shall pay its pro rata share of the cost of such utility service with all others served by 

  

 10 

 
the service not separately metered. Any interruption or cessation of Utilities resulting from any causes, including any entry for repairs pursuant to this
Lease, and any renovation, redecoration or rehabilitation of any area of the Project, shall not render Landlord liable for damages to either person or property or for interruption or loss to Tenant’s business, nor be construed as an eviction of
Tenant, nor work an abatement of any portion of Rent, nor relieve Tenant from fulfillment of any covenant or agreement hereof; provided, however, that if (i) an interruption of the Project services prevents Tenant from occupying all or a material
portion of the Premises for the Permitted Use for a period of at least seven (7) consecutive days and (ii) such interruption was caused by the gross negligence or willful misconduct of Landlord, its agents or employees, then monthly Rent shall
thereafter be proportionately abated during the period of such interruption. Nothing in this Section 4 shall limit the parties’ rights and obligations under Section 9 hereof, in the event of a casualty affecting the Building or Premises.
Landlord shall make commercially reasonable efforts to give Tenant at least forty-eight (48) hours prior written notice of any scheduled interruption in Project services to the Premises. 
  
 5. ALTERATIONS AND REPAIRS. 
  

A. Landlord’s Consent and Conditions. 
  
 1. Except for Minor Alterations (as defined below), Tenant shall not make any improvements or alterations to the Premises (the “Work”)
without in each instance submitting plans and specifications for the Work to Landlord and obtaining Landlord’s prior written consent. Tenant shall pay Landlord’s actual costs incurred for review of all of the plans and all other items
submitted by Tenant. Landlord will be deemed to be acting reasonably in withholding its consent for any Work which (a) materially impacts the base structural components or the Building Systems, (b) impacts any other tenant’s premises, (c) is
visible from outside the Premises, or (d) would utilize building materials or equipment which are inconsistent with Landlord’s standard building materials and equipment for the Building. 
  
 2. Landlord’s approval shall not be required for Work on the interior
of the Premises costing less than Fifty Thousand Dollars ($50,000.00) per project (“Minor Alterations”), provided that (a) Landlord would not have the right to reasonably withhold consent to the Work pursuant to clauses (1)(a)
through (1)(d) of Section 5.A(1) above; and (b) Tenant provides Landlord with written notice of such Minor Alteration, which shall include a copy of any governmental permits required to complete such Minor Alteration, if any, prior to commencing
construction of such Minor Alteration. 
  
 3. Tenant shall pay
for the cost of all Work, including the cost of any and all approvals, permits, fees and other charges which may be required as a condition of performing such Work. 
  
 4. The following requirements shall apply to all Work: 
  
 (a) Prior to commencement, Tenant shall furnish to Landlord (i) building permits, (ii) certificates of insurance
satisfactory to Landlord, and (iii) at Landlord’s request, a payment and performance bond in form reasonably acceptable to Landlord, in a principal amount not less than the estimated costs of such Work, to ensure Landlord against any liability
for mechanic’s and materialmen’s liens and to ensure completion of the Work. 
  

 11 

 (b) Tenant shall perform all Work so as to maintain peace and harmony among other contractors serving
the Project and shall avoid unreasonable interference with other work to be performed or services to be rendered in the Project. 
  
 (c) The Work shall be performed in a good and workmanlike manner, meeting the standard for construction and quality of materials in the Building, and
shall comply with all insurance requirements and all applicable laws, ordinances, regulations or requirements of the United States of America, the State of California, or the ordinances, regulations or requirements of the local municipal or county
governing body or other lawful authorities having jurisdiction over the Project, including, without limitation, any such laws, ordinances, regulations or requirements relating to hazardous materials or substances, as those terms are defined by
applicable laws now or hereafter in effect (collectively, “Governmental Requirements”). 
  
 (d) Tenant shall perform all Work so as to minimize or prevent unreasonable disruption to other tenants of the Project, and Tenant shall comply with all
reasonable requests of Landlord in response to complaints from other tenants. 
  
 (e) Tenant shall perform all Work in compliance with any “Policies, Rules and Procedures for Construction Projects” which may be in effect at the time the Work is performed. 
  
 (f) All Work shall be performed only by contractors or mechanics approved by
Landlord, which approval shall not be unreasonably withheld, conditioned or delayed; provided, however, that (i) Landlord may, in its sole discretion, specify engineers, general contractors, subcontractors, and architects to perform work affecting
the Building Systems; and (ii) if Landlord consents to any Work that requires work to be performed outside the Premises, Landlord may elect to perform such work at Tenant’s expense. 
  
 (g) Tenant shall permit Landlord to supervise all Work, including, without limitation, the right (but not an obligation) to
inspect the construction work during the progress thereof, and to require corrections of faulty construction or any material deviation from the plans for such Work as approved by Landlord; provided, however, that no such inspection shall be deemed
to create any liability on the part of Landlord, or constitute a representation by Landlord or any person hired to perform such inspection that the work so inspected conforms with such plans or complies with any Governmental Requirements, and no
such inspection shall give rise to a waiver of, or estoppel with respect to, Landlord’s continuing right at any time or from time to time to require the correction of any faulty work or any material deviation from such plans. 
  
 (h) Landlord may charge a supervisory fee not to exceed five percent (5%) of
labor, material, and all other costs of the Work to compensate Landlord for its review of plans and its management and supervision of the progress of the work. 
  

 12 

 (i) Upon completion, Tenant shall furnish Landlord with contractor’s affidavits and full and final
statutory waivers of liens, as-built plans and specifications, and receipted bills covering all labor and materials, and all other close-out documentation related to the Work, including any other information required under any “Policies, Rules
and Procedures for Construction Projects” which may be in effect at the time. 
  
 B. Repairs. If any part of the mechanical, electrical or other systems (e.g., HVAC, life safety or automatic fire extinguisher/sprinkler system) in the Premises (collectively, the “Building
Systems”) shall be damaged during the performance of the Work, Tenant shall promptly notify Landlord, and Landlord may elect to repair such damage at Tenant’s expense. Alternatively, Landlord may require Tenant to repair such damage at
Tenant’s sole expense using contractors approved by Landlord. 
  
 C. No Liens. Tenant has no authority to cause or permit any lien or encumbrance of any kind to affect Landlord’s interest in the Project; any such lien or encumbrance shall attach to Tenant’s interest only. If any
mechanic’s lien shall be filed or claim of lien made for work or materials furnished to Tenant, then Tenant shall at its expense within fifteen (15) days after Tenant receives written notice of any such lien either discharge or contest the lien
or claim. If Tenant contests the lien or claim, then Tenant shall (i) within such fifteen (15) day period, provide Landlord adequate security for the lien or claim, (ii) contest the lien or claim in good faith by appropriate proceedings that operate
to stay its enforcement, and (iii) pay promptly any final adverse judgment entered in any such proceeding. If Tenant does not comply with these requirements, Landlord may discharge the lien or claim, and the amount paid, as well as attorney’s
fees and other expenses incurred by Landlord, shall constitute Additional Rent payable by Tenant on demand. 
  
 D. Ownership of Improvements. All Work as defined in this Section 5, partitions, hardware, equipment, machinery and all other improvements and all
fixtures, except trade fixtures, constructed in the Premises by either Landlord or Tenant, (i) shall become Landlord’s property upon installation without compensation to Tenant, unless Landlord consents otherwise in writing, and (ii) shall, at
Landlord’s option, either (a) be surrendered to Landlord with the Premises at the termination of this Lease or of Tenant’s right to possession, or (b) be removed in accordance with Section 14 below (unless Landlord at the time it gives its
consent to the performance of such construction expressly waives in writing the right to require such removal). 
  
 6. USE OF PREMISES. 
  
 A. Limitation on Use. Tenant shall use the Premises only for the Permitted Use stated in the Schedule and Tenant shall not use or permit the
Premises or the Project to be used for any other purpose or purposes whatsoever without the prior written consent of Landlord. Landlord’s consent may be withheld in Landlord’s sole discretion. Tenant shall not allow any use of the Premises
which will negatively affect the cost of coverage of Landlord’s insurance on the Project. Tenant shall not allow any inflammable or explosive liquids or materials to be kept on the Premises. Tenant shall not allow any use of the Premises which
would cause the value or utility of any part of the Premises to diminish or would unreasonably interfere with any other tenant or with the operation of the Project by Landlord. Tenant shall not permit any nuisance or 

  

 13 

 
waste to occur in, on, or about the Project, or allow any offensive noise or odor in or around the Project. At the end of each business day, or more
frequently if necessary, Tenant shall deposit all garbage and other trash (excluding any inflammable, explosive and/or hazardous materials) in trash bins or containers approved by Landlord in locations designated by Landlord from time to time. If
any governmental authority shall deem the Premises to be a “place of public accommodation” under the Americans with Disabilities Act (“ADA”) or any other comparable law as a result of Tenant’s use, Tenant shall either
modify its use to cause such authority to rescind its designation or be responsible for any alterations, structural or otherwise, required to be made to the Building or the Premises under such laws. 
  
 B. Signs. Tenant shall not place on any portion of the Premises any
sign, placard, lettering, banner, displays, graphic, decor or other advertising or communicative material which is visible from the exterior of the Premises without Landlord’s prior written approval; provided, however, that Tenant shall have
the right to install one (1) sign identifying Tenant on the Building, and one (1) sign identifying Tenant on the existing Building monument sign. The material, typeface, graphic format and proportions of Tenant’s signs, as well as the precise
location of such signs, shall be subject to Landlord’s approval, which shall not be unreasonably withheld, and any approval required under Governmental Requirements. Any signs approved hereunder shall strictly conform to all Governmental
Requirements, any CC&R’s recorded against the Project, and Landlord’s signage standards in effect at the time, and shall be installed and removed at Tenant’s expense. Tenant, at its sole expense, shall maintain such signs in good
condition and repair during the Term. Prior to the expiration or earlier termination of this Lease, Tenant at its sole cost shall remove all of its exterior signage and repair any and all damage caused to the Building and/or Project (including and
fading or discoloration) by such signs and/or the removal of such signs from the Building and/or Project. 
  
 C. Parking. Tenant shall have the non-exclusive right to park in the Project’s parking facilities in common with other tenants of the Project
upon terms and conditions, as may from time to time be established by Landlord. Tenant agrees not to overburden the parking facilities (i.e., use more than the number of unassigned parking stalls indicated on the Schedule) and agrees to
cooperate with Landlord and other tenants in the Project in the use of the parking facilities. Landlord reserves the right in its discretion to determine whether the parking facilities are becoming crowded and to allocate and assign parking passes
among Tenant and the other tenants in the Project; provided, however, that no such allocation or assignment shall reduce the number of parking spaces, as set forth in the Schedule, that Tenant is entitled to use. Tenant’s use of the parking
facilities shall be at no charge during the Term, except that Landlord shall have the right to charge Tenant the portion that Landlord reasonably deems allocable to Tenant of any charges (e.g., fees or taxes) imposed by the Regional Air
Quality Control Board or other governmental or quasi-governmental agency in connection with the parking facilities (e.g., in connection with operation or use of the parking facilities). Landlord shall not be liable to Tenant, nor shall this
Lease be affected, if any parking is impaired by (or if any parking charges are imposed as a result of) any moratorium, initiative, referendum, law, ordinance, regulation or order passed, issued or made by any governmental or quasi-governmental
body. Tenant’s continued right to use the parking spaces is conditioned upon Tenant abiding by all rules and regulations which are prescribed from time to time for the orderly operation and use of the parking facility where the parking passes
are located, including any sticker or other identification system established by Landlord, Tenant’s cooperation in seeing that Tenant’s employees and 

  

 14 

 
visitors also comply with such rules and regulations and Tenant not being in default under this Lease. Landlord specifically reserves the right to change the
size, configuration, design, layout and all other aspects of the Project parking facility at any time, provided, however, that no such allocation or assignment shall reduce the number of parking spaces, as set forth in the Schedule, that Tenant is
entitled to use, and Tenant acknowledges and agrees that Landlord may, without incurring any liability to Tenant and without any abatement of Rent under this Lease, from time to time, close-off or restrict access to the Project parking facility for
purposes of permitting or facilitating any such construction, alteration or improvements. Landlord may delegate its responsibilities hereunder to a parking operator in which case such parking operator shall have all the rights of control attributed
hereby to the Landlord. The parking passes under this Section 6.C are provided to Tenant solely for use by Tenant’s own personnel and such passes may not be transferred, assigned, subleased or otherwise alienated by Tenant without
Landlord’s prior approval unless in connection with an assignment, sublease or other alienation of Tenant’s interest in this Lease pursuant to Section 17 below. 
  
 D. Prohibition Against Use of Roof and Structure of Building. 
  
 1. Tenant shall be prohibited from using all or any portion of the
structure of the Building during the Term of this Lease (or any extensions thereof) for any purposes, without the prior written consent of Landlord, which consent Landlord may withhold in its sole and absolute discretion. Tenant shall be prohibited
from using all or any portion of the roof of the Building during the Term of this Lease (or any extensions thereof) for any purposes, without the prior written consent of Landlord, which consent, provided that Tenant’s use of the roof will be
limited to the installation of non-revenue producing equipment to service Tenant’s business in the Premises, shall not be unreasonably withheld, conditioned or delayed (otherwise Landlord may withhold its consent in its sole and absolute
discretion). Notwithstanding the foregoing, however, subject to the remaining provisions of this Section 6.D (regarding Landlord’s approval of plans and specifications, etc.), Landlord hereby consents to Tenant’s installation of a rooftop
satellite dish and antenna (including a 30” long antenna) to service Tenant’s business in the Premises. Tenant shall submit to Landlord, with any request for consent of any rooftop equipment, plans and specifications therefor, which must
include, without limitation, the design, size and features of the rooftop equipment and mounting structure, floor and power load requirements, cabling installations, the means of affixing or mounting the rooftop equipment, and the means of
connecting the rooftop equipment to the Building’s electrical system and to the Premises. 
  
 2. Tenant acknowledges and agrees that Tenant’s use of any portion of the roof of the Building shall be non-exclusive and subject to such reasonable
rules and regulations as Landlord may prescribe, including, without limitation, with regard to (a) the location, size, type and methods of installation of the proposed rooftop equipment, (b) requirements to prevent electrical, electromagnetic, radio
frequency or other interference with other telecommunication equipment on or about the Building, (c) rooftop space availability, (d) restrictions on penetration of the roof surface, (e) rooftop access rights and (f) removal requirements upon the
expiration or earlier termination of this Lease. Landlord has made no representations or promise as to the suitability or effectiveness of any part of the roof for Tenant’s proposed use, or as to any Governmental Requirements applicable to
Tenant’s proposed use. The routes or paths for wiring and connections to any approved rooftop equipment shall be 

  

 15 

 
through the Building’s existing risers, conduits and shafts, subject to reasonable space limitations and Landlord’s requirements for use of such
areas, and in all events subject to Landlord’s approval of location, plans and installation pursuant to Section 5 of this Lease. 
  
 3. Nothing in this Section 6.D shall limit or restrict Landlord’s rights under Section 11.N, or require Landlord to obtain Tenant’s consent
prior to exercising such rights. 
  
 7. GOVERNMENTAL
REQUIREMENTS AND BUILDING RULES. 
  
 A. Compliance in
Premises. 
  
 1. Landlord’s Responsibilities. At
the time of delivery to Tenant, the Premises (including Landlord’s Work) shall be in compliance with all applicable Governmental Requirements as interpreted by applicable governmental or quasi-governmental authorities as of such date, without
regard to any specific use of the Premises by Tenant; provided, however, that if Landlord fails to deliver the Premises in such condition, as evidenced by written notice of violation from any applicable governmental agency(ies) with jurisdiction,
Landlord, at Landlord’s expense, shall, as Tenant’s sole remedy therefor, perform such work in the Premises as may be necessary to cure the violation of the Governmental Requirements which existed as of the date of delivery. 
  
 2. Tenant’s Responsibilities. Tenant shall, at its sole cost and
expense, (1) comply with all Governmental Requirements; with any occupancy certificate issued for the Premises; and with the provisions of all recorded documents affecting the Premises, insofar as any thereof relates to or affects the condition, use
or occupancy of the Premises; and (2) take all proper and necessary action to cause the Premises, including any repairs, replacements, alterations and improvements thereto, to be maintained, constructed, used and occupied in compliance with
applicable Governmental Requirements, including any applicable code and ADA requirements, whether or not such requirements are based on Tenant’s use of the Premises, and further to assume all responsibility to ensure the Premises’
continued compliance with all Governmental Requirements, including applicable code and ADA requirements, throughout the Term. Tenant shall be responsible, at its sole cost and expense, to make all alterations to the Premises as are required to
comply with the governmental rules, regulations, requirements or standards described in this Section 7.A. The judgment of any court of competent jurisdiction or the admission of Tenant in any judicial action, regardless of whether Landlord is a
party thereto, that Tenant has violated any of said governmental measures, shall be conclusive of that fact as between Landlord and Tenant. 
  
 B. Compliance in Common Areas. Subject to reimbursement as an Operating Cost as provided in Section 2 above, Landlord shall perform any work
required under any applicable Governmental Requirements, including the ADA, to be performed in the common areas of the Project, except that Tenant shall be solely responsible for all such compliance work which is required as a result of
Tenant’s use of or activities in the Premises, or which relates to Tenant’s Work in or to the Premises. With respect to any code compliance work required outside the Premises for which Tenant is responsible hereunder, Landlord shall have
the right to perform such work, or require that Tenant perform such work with contractors, subcontractors, engineers 

  

 16 

 
and architects approved by Landlord; and if Landlord elects to perform such work outside the Premises, Tenant shall reimburse Landlord for the cost of such
work within ten (10) days following receipt of invoices therefor. Landlord makes no representations or warranties regarding whether the Project or the Premises complies with applicable Governmental Requirements as of the date of this Lease;
provided, however, that Landlord represents to Tenant that, as of the date of this Lease, Landlord has not received any written notice from any governmental authority that common areas of the Project are in violation of any Governmental
Requirements, which violation remains uncured. If it is determined that the foregoing representation was untrue when made, Landlord shall, as Tenant’s sole and exclusive remedy, perform such work as may be required by such Governmental
Requirements, but only to the extent that failure to do so would result in an obligation or liability accruing to Tenant or result in an imminent and material adverse impact on Tenant’s occupancy of or access to the Premises. 
  
 C. Rules and Regulations. Tenant shall also comply with all reasonable
rules for the Project which may be established and amended from time to time by Landlord; provided, however, Tenant shall not be responsible for compliance with any rule promulgated after the date of this Lease until Landlord has made a reasonable
effort to notify Tenant of such rule and such rule does not materially increase the obligations of Tenant hereunder or materially decrease the rights of Tenant hereunder. The present rules and regulations are contained in Exhibit B. Failure by
another tenant to comply with the rules or failure by Landlord to enforce them shall not relieve Tenant of its obligation to comply with the rules or make Landlord responsible to Tenant in any way. Landlord shall use reasonable efforts to apply the
rules and regulations uniformly with respect to Tenant and any other tenants in the Project under leases containing rules and regulations similar to this Lease. 
  

8. WAIVER OF CLAIMS; INDEMNIFICATION; INSURANCE. 
  
 A. Waiver of Claims. Neither Landlord nor the other Indemnitees (as defined below) shall be liable to Tenant or to any Tenant Parties (as defined
below), and Tenant waives all claims against Landlord and such other Indemnitees, for any injury to or death of any person or for loss of use of or damage to or destruction of property in or about the Premises or Project by or from any cause
whatsoever, including without limitation, earthquake or earth movement, gas, fire, oil, electricity or leakage from the roof, walls, basement or other portion of the Premises or Project, except only, with respect to any Indemnitee, to the extent
such injury, death or damage is caused by the gross negligence or willful misconduct of such Indemnitee and not covered by the insurance required to be carried by Tenant hereunder or except to the extent such limitation on liability is prohibited by
law. The provisions of this Section 8.A shall survive the expiration or earlier termination of this Lease until all claims within the scope of this Section 8.A are fully, finally, and absolutely barred by the applicable statutes of limitations.

  
 B. Indemnification. 
  
 1. Tenant shall indemnify, protect, defend (by counsel reasonably
satisfactory to Landlord) and hold harmless Landlord and its officers, directors, employees and agents (each, an “Indemnitee” and collectively, the “Indemnitees”), and each of them, against any and all obligations,
losses, claims, actions (including remedial or enforcement actions of any kind and administrative or judicial proceedings, suits, orders or judgments), causes of action, 

  

 17 

 
liabilities, penalties, damages (including consequential and punitive damages), costs and expenses (including reasonable attorneys’ and
consultants’ fees and expenses) (collectively, “Claims”) arising from any of the following, including, but not limited to, Claims brought by or on behalf of employees of Tenant, with respect to which Tenant waives, for the
benefit of the Indemnitees, any immunity to which Tenant may be entitled under any worker’s compensation laws: (a) any cause in, on or about the Premises, (b) any act or omission or negligence of Tenant or any person or entity claiming by or
through Tenant (including any assignee or subtenant), or any of their respective members, partners, employees, contractors, agents, customers, visitors, licensees or other persons in or about the Project by reason of Tenant’s occupancy of the
Premises (each a “Tenant Party” and, collectively, “Tenant Parties”), or (c) Tenant’s breach of its obligations under this Lease, either prior to, during, or after the expiration of the Lease Term; provided,
however, that, with respect to any Indemnitee, Tenant’s obligations under this Section shall be inapplicable to the extent such Claims arise from the gross negligence or willful misconduct of such Indemnitee and are not covered by the insurance
required to be carried by Tenant hereunder, or to the extent such obligations are prohibited by applicable law. 
  
 2. Tenant’s duty to defend Landlord and the other Indemnitees under this Section 8.B is separate and independent of Tenant’s duty to indemnify
the Indemnitees. The duty to defend includes claims for which the Indemnitees may be liable without fault or strictly liable. The duty to defend applies regardless of whether the issues of negligence, liability, fault, default, or other obligation
on the part of Tenant Parties have been determined. The duty to defend applies immediately, regardless of whether any Indemnitees have paid any sums or incurred any detriment arising out of or relating (directly or indirectly) to any Claims. The
parties expressly intend that Indemnitees shall be entitled to obtain summary adjudication or summary judgment regarding Tenant’s duty to defend the Indemnitees at any stage of any claim or suit within the scope of this Section. 
  
 3. Subject to the waivers of liability and subrogation set forth in Sections
8.A and 8.F, respectively, Landlord shall indemnify and hold harmless Tenant, its officers, agents and employees from and against all Claims to the extent arising from the gross negligence or willful misconduct of Landlord, its employees, agents or
contractors. 
  
 4. The obligations of Tenant and Landlord under
this Section shall survive the expiration or earlier termination of this Lease until all Claims within the scope of this Section 8.B are fully, finally, and absolutely barred by the applicable statutes of limitations. 
  
 C. Tenant’s Insurance. Tenant shall maintain insurance as
follows, with such other terms, coverages and insurers, as Landlord shall reasonably require from time to time: 
  
 1. Commercial General Liability Insurance, with (a) Contractual Liability including the indemnification provisions contained in this Lease, (b) a
severability of interest endorsement, (c) limits of not less than Three Million Dollars ($3,000,000) combined single limit per occurrence and not less than Three Million Dollars ($3,000,000) in the aggregate for bodily injury, sickness or death, and
property damage, and umbrella coverage of not less than Five Million Dollars ($5,000,000). 
  

 18 

 2. Property Insurance against “All Risks” of physical loss covering the replacement cost of
all improvements, fixtures and personal property (including the Landlord’s Personal Property under Section 33 below). 
  
 3. Workers’ compensation or similar insurance in form and amounts required by law, and Employer’s Liability with not less than the following
limits: 
  

	 Each Accident:
	  	$	500,000
	 Disease—Policy Limit:
	  	$	500,000
	 Disease—Each Employee:
	  	$	500,000

  
 Tenant’s
insurance shall be primary and not contributory to that carried by Landlord, its agents, or mortgagee. Landlord, and if any, Landlord’s building manager or agent, mortgagee and ground lessor shall be named as additional insureds under the
insurance required of the Tenant in Section 8.C(1). The company or companies writing any insurance which Tenant is required to maintain under this Lease, as well as the form of such insurance, shall at all times be subject to Landlord’s
approval, and any such company shall be licensed to do business in the state in which the Building is located. Such insurance companies shall have a A.M. Best rating of A- VI or better. 
  
 4. Tenant shall cause any contractor of Tenant performing work on the Premises to maintain insurance as follows, with such
other terms, coverages and insurers, as Landlord shall reasonably require from time to time: 
  
 (a) Commercial General Liability Insurance, including contractor’s liability coverage, contractual liability coverage, completed operations coverage, broad form property damage endorsement, and contractor’s
protective liability coverage, to afford protection with limits, for each occurrence, of not less than One Million Dollars ($1,000,000) with respect to personal injury, death or property damage. 
  
 (b) Workers’ compensation or similar insurance in form and amounts
required by law, and Employer’s Liability with not less than the following limits: 
  

	 Each Accident:
	  	$	500,000
	 Disease—Policy Limit:
	  	$	500,000
	 Disease—Each Employee:
	  	$	500,000

  
 Such insurance shall
contain a waiver of subrogation provision in favor of Landlord and its agents. Tenant’s contractor’s insurance shall be primary and not contributory to that carried by Tenant, Landlord, their agents or mortgagees. Tenant and Landlord, and
if any, Landlord’s building manager or agent, mortgagee or ground lessor shall be named as additional insured on Tenant’s contractor’s insurance policies. 
  
 D. Insurance Certificates. Tenant shall deliver to Landlord certificates evidencing all required insurance no later
than five (5) days prior to the Commencement Date and each renewal date. Each certificate will provide for thirty (30) days prior written notice of cancellation to Landlord and Tenant. 
  

 19 

 E. Landlord’s Insurance. Subject to reimbursement as an Operating Cost in accordance with the
provisions of Section 2 hereof, Landlord shall procure and maintain in effect throughout the Term of this Lease commercial general liability insurance, full replacement cost property insurance and/or such other types of insurance Landlord reasonably
deems necessary or advisable to carry. Such coverages shall be in such amounts, from such companies and on such other terms and conditions as Landlord may from time to time reasonably determine, and Landlord shall have the right, but not the
obligation, to change, cancel, decrease or increase any insurance coverages in respect of the Building, add additional forms of insurance as Landlord shall deem reasonably necessary, and/or obtain umbrella or other policies covering both the
Building and other assets owned by or associated with Landlord or its affiliates, in which event the cost thereof shall be equitably allocated. 
  
 F. Waiver of Subrogation. Landlord and Tenant hereby waive and release any and all rights of recovery against the other party, including officers,
employees, agents and authorized representatives (whether in contract or tort) of such other party, that arise or result from any and all loss of or damage to any property of the waiving party located within or constituting part of the Building,
including the Premises, to the extent of amounts payable under a standard ISO Commercial Property insurance policy, or such additional property coverage as the waiving party may carry (with a commercially reasonable deductible), whether or not the
party suffering the loss or damage actually carries any insurance, recovers under any insurance or self-insures the loss or damage. Each party shall have their property insurance policies issued in such form as to waive any right of subrogation as
might otherwise exist. This mutual waiver is in addition to any other waiver or release contained in this Lease. 
  
 9. FIRE AND OTHER CASUALTY. 
  
 A. Termination. If a fire or other casualty causes damage to the Building or the Premises, and sufficient insurance proceeds will be available to
Landlord to cover the cost of any restoration to the Building and Premises (provided that Landlord shall have maintained the insurance coverage required to be maintained by Landlord under this Lease), Landlord shall engage a registered architect to
estimate, within one (1) month of the casualty, to both Landlord and Tenant the amount of time needed to restore the Building, Premises and Landlord’s Work to tenantability, using standard working methods without the payment of overtime and
other premiums. If the time needed exceeds twelve (12) months from the beginning of the restoration, or two (2) months therefrom if the restoration would begin during the last twelve (12) months of the Lease, then in the case of damage to the
Premises, either Landlord or Tenant may terminate this Lease, and in the case of damage to the Building, Landlord may terminate this Lease, by notice to the other party within ten (10) days after the notifying party’s receipt of the
architect’s estimate. If sufficient insurance proceeds will not be available to Landlord to cover the cost of any restoration to the Building or the Premises (provided that Landlord shall have maintained the insurance coverage required to be
maintained by Landlord under this Lease), Landlord may terminate this Lease by written notice to Tenant. Any termination pursuant to this Section 9.A shall be effective thirty (30) days from the date of such termination notice and Rent shall be paid
by Tenant to that date, with an abatement for any portion of the Premises which has been rendered untenantable as a result of the casualty (except to the extent that the casualty was caused by the negligence or intentional misconduct of Tenant, its
agents, employees, contractors, subtenants or assignees). 
  

 20 

 B. Restoration. If a casualty causes damage to the Building or the Premises but this Lease is not
terminated for any reason, then subject to the rights of any mortgagees or ground lessors, Landlord shall obtain the applicable insurance proceeds and diligently restore the Building, Premises and Landlord’s Work subject to current Governmental
Requirements. Landlord’s obligation, should it elect or be obligated to repair or rebuild, shall be limited to the basic Premises, building-standard tenant improvements, or the basic Building, as the case may be, and Tenant shall, at
Tenant’s expense, replace or fully repair damaged improvements made pursuant to Section 5 hereof, any tenant improvements in excess of the building standard, personal property and fixtures. Rent shall be abated on a per diem basis during the
restoration for any portion of the Premises which is untenantable, except to the extent that the casualty was caused by the negligence or intentional misconduct of Tenant, its agents, employees, contractors, subtenants or assignees. Tenant shall not
be entitled to any compensation or damages from Landlord for loss of the use of the Premises, damage to Tenant’s personal property and trade fixtures or any inconvenience occasioned by such damage, repair or restoration. Tenant hereby waives
the provisions of Section 1932, Subdivision 2, and Section 1933, Subdivision 4, of the California Civil Code, and the provisions of any similar law hereinafter enacted. 
  
 10. EMINENT DOMAIN. If a part of the Project is taken by eminent domain or deed in lieu thereof which is so
substantial that the Premises cannot reasonably be used by Tenant for the operation of its business, then either party may terminate this Lease effective as of the date of the taking. If any substantial portion of the Project is taken without
affecting the Premises, then Landlord may terminate this Lease as of the date of such taking. Rent shall abate from the date of the taking in proportion to any part of the Premises taken. The entire award for a taking of any kind shall be paid to
Landlord, and Tenant shall have no right to share in the award. All obligations accrued to the date of the taking shall be performed by the party liable to perform said obligations, as set forth herein. Tenant hereby waives any and all rights it
might otherwise have pursuant to Section 1265.130 of The California Code of Civil Procedure. 
  
 11. RIGHTS RESERVED TO LANDLORD. 
  
 Landlord may exercise at any time any of the following rights respecting the operation of the Project without liability to Tenant of any kind: 
  
 A. Name. To change the name of the Project or the street address of the Building unless required by any applicable
governmental agency. 
  
 B. Signs. To install, modify
and/or maintain any signs in the common areas of the Project, and to approve at its sole discretion, prior to installation, any of Tenant’s signs in the Premises visible from the common areas or the exterior of the Building, subject to Section
6(B) above. 
  
 C. Window Treatments. To approve, at its
discretion, prior to installation, any shades, blinds, ventilators or window treatments of any kind, as well as any lighting within the Premises that may be visible from the exterior of the Building. 
  

 21 

 D. Keys. To retain and use at any time, as permitted under this Lease, passkeys to enter the
Premises or any door within the Premises. Tenant shall not alter or add any lock or bolt without notice to Landlord. 
  
 E. Access. To have access to the Premises with twenty-four hours’ prior notice (except in the case of an emergency, in which case Landlord
shall have the right to immediate access) to inspect the Premises, to post notices of non-responsibility in connection with any Work, to make repairs, alterations, additions or improvements to the Premises or Building, and to perform any other
obligations of Landlord hereunder, all without abatement of Rent; provided, however, that Landlord, in connection with the foregoing, shall use commercially reasonable efforts to minimize interference with Tenant’s business in the Premises.

  
 F. Preparation for Reoccupancy. To decorate, remodel,
repair, alter or otherwise prepare the Premises for reoccupancy at any time after Tenant abandons the Premises, without relieving Tenant of any obligation to pay Rent. 
  
 G. Heavy Articles. To approve the weight, size, placement and time and manner of movement within the Building of any
safe, central filing system or other heavy article of Tenant’s property. Tenant shall move its property entirely at its own risk. 
  
 H. Show Premises. To show the Premises to prospective purchasers, tenants (in the last six months of the Term), brokers, lenders, mortgagees,
investors, rating agencies or others, at any reasonable time, provided that Landlord gives prior notice to Tenant and does not materially interfere with Tenant’s use of the Premises. 
  
 I. Intentionally omitted. 
  
 J. Use of Lockbox. To designate a lockbox collection agent for collections of amounts due Landlord. In that case, the date of payment of Rent or
other sums shall be the date of the agent’s receipt of such payment or the date of actual collection if payment is made in the form of a negotiable instrument thereafter dishonored upon presentment. However, Landlord may reject any payment for
all purposes as of the date of receipt or actual collection by mailing to Tenant within a reasonable time after such receipt or collection a check equal to the amount sent by Tenant. 
  
 K. Repairs and Alterations. To make repairs or alterations to the Project and, if making repairs to the Building,
transport any required material through the Premises, to close entrances, doors, corridors, elevators and other facilities in the Project, to open any ceiling in the Premises, or to temporarily suspend services in the Building; provided that,
subject to the next succeeding sentence, Landlord shall, in connection with the foregoing work, use commercially reasonable efforts to minimize interference with Tenant’s business in the Premises. Landlord may perform any such repairs or
alterations during ordinary business hours, except that Tenant may require any work in the Premises to be done after business hours if Tenant pays Landlord for overtime and any other expenses incurred. Landlord may do or permit any work on any
nearby building, land, street, alley or way. Notwithstanding the foregoing, in making repairs to the Building, Landlord shall provide Tenant with at least twenty-four hours’ prior notice (except in the case of an emergency, in which case
Landlord shall have the right to immediate access, or for purposes of providing regularly scheduled services). 
  

 22 

 L. Building Services. To install, use and maintain through the Premises, pipes, conduits, wires
and ducts serving the Building, provided that such installation, use and maintenance does not unreasonably interfere with Tenant’s use of the Premises. 
  
 M. Use of Roof. To install, operate, maintain and repair any satellite dish, antennae, equipment, or other facility on the roof of the Building or
to use the roof of the Building in any other manner, or to allow any entity selected by Landlord to undertake the foregoing, provided that such installation, operation, maintenance, repair or use does not unreasonably interfere with Tenant’s
use of the Premises. 
  
 N. Other Actions. To take any
other action which Landlord deems reasonable in connection with the operation, maintenance or preservation of the Building and the Project; provided, however, that Landlord shall use commercially reasonable efforts to minimize interference with
Tenant’s business in the Premises. 
  
 12. DEFAULTS.

  
 A. Tenant’s Default. Any of the following shall
constitute a default by Tenant: 
  
 1. Rent Default.
Tenant fails to pay any Rent and such failure continues for five (5) days or more following Landlord’s written notice of such failure; 
  
 2. Assignment/Sublease or Hazardous Substances Default. Tenant defaults in its obligations under Section 16 (Subordination), Section 17
(Assignment and Sublease), Section 19 (Estoppel Certificate) or Section 28 (Hazardous Substances); 
  
 3. Other Performance Default. Tenant fails to perform any other obligation to Landlord under this Lease, and such failure continues for twenty
(20) days after written notice from Landlord or Landlord’s agent, except that if Tenant begins to cure its failure within the twenty (20) day period but cannot reasonably complete its cure within such period, then, so long as Tenant continues
to diligently attempt to cure its failure, the twenty (20) day period shall be extended to sixty (60) days, or such lesser period as is reasonably necessary to complete the cure; 
  
 4. Credit Default. One of the following credit defaults occurs: 
  
 (a) Tenant (or any guarantor of Tenant’s obligations hereunder)
commences any proceeding under any law relating to bankruptcy, insolvency, reorganization or relief of debts, or seeks appointment of a receiver, trustee, custodian or other similar official for the Tenant (or the guarantor) or for any substantial
part of its property, or any such proceeding is commenced against Tenant (or the guarantor) and either remains undismissed for a period of thirty (30) days or results in the entry of an order for relief against Tenant (or the guarantor) which is not
fully stayed within seven (7) days after entry; 
  

 23 

 (b) Tenant (or any guarantor of Tenant’s obligations hereunder) becomes insolvent or bankrupt, does
not generally pay its debts as they become due, or admits in writing its inability to pay its debts, or makes a general assignment for the benefit of creditors; 
  

(c) Any third party obtains a levy or attachment under process of law against Tenant’s leasehold interest. 
  
 5. Abandonment Default. Tenant abandons the Premises. 
  
 6. Existing Lease. Tenant fails to perform any of the monetary
obligations required to be performed by Tenant under its existing lease with Landlord (as successor-in-interest to Orchard Investment Company Number 510, a California general partnership) dated November 29, 1993, after the required notice and
applicable cure period set forth therein, if any. 
  
 Tenant
acknowledges and agrees that, notwithstanding the foregoing provisions of this Section 12, Tenant shall be in default for purposes of Section 1161 of the California Code of Civil Procedure immediately following Tenant’s failure to perform or
comply with any covenants, agreements, terms or conditions of this Lease to be performed or observed by Tenant, including, without limitation, Tenant’s failure to pay Rent when due, and that any notices required to be given by Landlord under
this Section 12 shall, in each case, be in lieu of, and not in addition to, any notice required under Section 1161 of the California Code of Civil Procedure, and shall be deemed to satisfy the requirement, if any, that notice be given pursuant to
such section. 
  
 B. Landlord Defaults. Landlord shall be
in default hereunder if Landlord has not begun and pursued with reasonable diligence the cure of any failure of Landlord to meet its obligations hereunder within thirty (30) days after the receipt by Landlord of written notice from Tenant of the
alleged failure to perform. In no event shall Tenant have the right to terminate or rescind this Lease as a result of Landlord’s default as to any covenant or agreement contained in this Lease. Tenant hereby waives such remedies of termination
and rescission and hereby agrees that Tenant’s remedies for default hereunder and for breach of any promise or inducement shall be limited to a suit for damages and/or injunction. In addition, Tenant hereby covenants that, prior to the exercise
of any such remedies, Tenant will give notice and a reasonable time to cure any default by Landlord to any holder of a mortgage or deed of trust encumbering Landlord’s interest in the Project of which Tenant has been given notice.
Notwithstanding anything contained in this Lease to the contrary, Landlord shall not be in default hereunder to the extent Landlord is unable to perform any of its obligations on account of any prevention, delay, stoppage due to strikes, lockouts,
inclement weather, labor disputes, inability to obtain labor, materials, fuels, energy or reasonable substitutes therefor, governmental restrictions, regulations, controls, actions or inaction, civil commotion, fire or other acts of god, national
emergency, acts of war or terrorism or any other cause of any kind beyond its reasonable control (except financial inability). 
  

 24 

 13. LANDLORD REMEDIES. UPON A DEFAULT, LANDLORD SHALL HAVE THE FOLLOWING REMEDIES, IN ADDITION TO
ALL OTHER RIGHTS AND REMEDIES PROVIDED BY LAW OR OTHERWISE PROVIDED IN THIS LEASE, TO WHICH LANDLORD MAY RESORT CUMULATIVELY OR IN THE ALTERNATIVE: 
  
 A. Termination of Lease. Landlord may elect by notice to Tenant to terminate this Lease, in which event, Tenant shall immediately vacate the
Premises and deliver possession to Landlord. 
  
 B. Civil Code
Section 1951.4 Remedy. Even though Tenant has breached this Lease, this Lease shall continue in effect for so long as Landlord does not terminate Tenant’s right to possession, and Landlord shall have all of its rights and remedies,
including the right, pursuant to California Civil Code Section 1951.4, to recover all rent as it becomes due under this Lease, if Tenant has the right to sublet or assign, subject only to reasonable limitations. Acts of maintenance or preservation
or efforts to relet the Premises or the appointment of a receiver upon initiative of Landlord to protect Landlord’s interest under this Lease shall not constitute a termination of Tenant’s right to possession unless written notice of
termination is given by Landlord to Tenant. 
  
 C. Lease
Termination Damages. If Landlord elects to terminate this Lease, then this Lease shall terminate on the date for termination set forth in such notice. Tenant shall immediately vacate the Premises and deliver possession to Landlord, and Landlord
may repossess the Premises and may, at Tenant’s sole cost, remove any of Tenant’s signs and any of its other property, without relinquishing its right to receive Rent or any other right against Tenant. On termination, Landlord has the
right to recover from Tenant as damages: 
  
 1. The worth at the
time of award of unpaid Rent and other sums due and payable which had been earned at the time of termination; plus 
  
 2. The worth at the time of award of the amount by which the unpaid Rent and other sums due and payable which would have been earned after termination
until the time of award exceeds the amount of such Rent loss that Tenant proves could have been reasonably avoided; plus 
  
 3. The worth at the time of award of the amount by which the unpaid Rent and other sums due and payable for the balance of the Term after the time of
award exceeds the amount of such Rent loss that Tenant proves could be reasonably avoided; plus 
  
 4. Any other amount necessary to compensate Landlord for all the detriment proximately caused by Tenant’s failure to perform Tenant’s
obligations under this Lease, or which, in the ordinary course of things, would be likely to result therefrom, including, without limitation, any costs or expenses incurred by Landlord: (i) in retaking possession of the Premises; (ii) in
maintaining, repairing, preserving, restoring, replacing, cleaning, altering or rehabilitating the Premises or any portion thereof, including such acts for reletting to a new tenant or tenants; (iii) for leasing commissions; or (iv) for any other
costs necessary or appropriate to relet the Premises; plus 
  

 25 

 5. At Landlord’s election, such other amounts in addition to or in lieu of the foregoing as may be
permitted from time to time by the laws of the State of California. 
  
 The “worth at the time of award” of the amounts referred to in Sections 13.C(1) and 13.C(2) is computed by allowing interest at the Interest Rate on the unpaid rent and other sums due and payable from the termination date
through the date of award. The “worth at the time of award” of the amount referred to in Section 13.C(3) is computed by discounting such amount at the discount rate of the Federal Reserve Bank of San Francisco at the time of award
plus one percent (1%). Tenant waives redemption or relief from forfeiture under California Code of Civil Procedure Sections 1174 and 1179, or under any other present or future law, if Tenant is evicted or Landlord takes possession of the Premises by
reason of any default of Tenant hereunder. 
  
 D.
Landlord’s Remedies Cumulative. All of Landlord’s remedies under this Lease shall be in addition to all other remedies Landlord may have at law or in equity, including, without limitation, the remedy described in California Civil
Code Section 1951.4 (pursuant to which Landlord may continue this Lease in effect after Tenant’s breach and abandonment and recover rent as it becomes due if Tenant has the right to sublet or assign the Lease, subject to reasonable
limitations). Waiver by Landlord of any breach of any obligation by Tenant shall be effective only if it is in writing, and shall not be deemed a waiver of any other breach, or any subsequent breach of the same obligation. The possession of
Tenant’s funds, negotiation of Tenant’s negotiable instruments, or acceptance of Tenant’s payment by Landlord or its agents shall not constitute a waiver of any breach by Tenant, and if such possession, negotiation or acceptance
occurs after Landlord’s notice to Tenant, or termination of this Lease or of Tenant’s right to possession, such possession, negotiation or acceptance shall not affect such notice or termination. Acceptance of payment by Landlord after
commencement of a legal proceeding or final judgment shall not affect such proceeding or judgment. Landlord may advance such monies and take such other actions for Tenant’s account as reasonably may be required to cure or mitigate any default
by Tenant. Tenant shall immediately reimburse Landlord for any such advance, and such sums shall bear interest at the Interest Rate until paid. 
  
 E. WAIVER OF TRIAL BY JURY. EACH PARTY WAIVES TRIAL BY JURY IF ANY LEGAL PROCEEDING IS BROUGHT BY THE OTHER IN CONNECTION WITH THIS
LEASE. EACH PARTY SHALL BRING ANY ACTION AGAINST THE OTHER IN CONNECTION WITH THIS LEASE IN A FEDERAL OR STATE COURT LOCATED IN CALIFORNIA, CONSENTS TO THE JURISDICTION OF SUCH COURTS, AND WAIVES ANY RIGHT TO HAVE ANY PROCEEDING TRANSFERRED FROM
SUCH COURTS ON THE GROUND OF IMPROPER VENUE OR INCONVENIENT FORUM. THE PROVISIONS OF THIS SECTION 13.E SHALL SURVIVE THE EXPIRATION OR EARLIER TERMINATION OF THIS LEASE. 
  
 14. SURRENDER. Upon the expiration or earlier termination of this Lease for any reason, Tenant shall surrender the
Premises to Landlord in its condition existing as of the date Landlord delivers possession of the Premises to Tenant, normal wear and tear and damage by fire or other casualty excepted, with all interior walls repaired if damaged, all broken
acoustical ceiling tiles replaced, all windows washed, the plumbing and electrical systems and lighting in good order and repair, including replacement of any burned out or broken light bulbs or ballasts, the HVAC equipment serviced and repaired by
a reputable and licensed service firm acceptable 
  

 26 

 to Landlord, and all floors cleaned and waxed, all to the reasonable satisfaction of Landlord. Tenant shall remove from
the Premises and the Project all of Tenant’s trade fixtures, furniture, moveable equipment and other personal property, and any Work which Landlord elects to be removed pursuant to Section 5.D, and shall restore the Premises to their condition
prior to their installation, including, without limitation, repairing all damage caused by the installation or removal of any of the foregoing items. If Tenant does not timely remove such property, then Tenant shall be conclusively presumed to have,
at Landlord’s election: (a) conveyed such property to Landlord without compensation or (b) abandoned such property, and Landlord may dispose of or store any part thereof in any manner at Tenant’s sole cost, without waiving Landlord’s
right to claim from Tenant all expenses arising out of Tenant’s failure to remove the property, and without liability to Tenant or any other person. Landlord shall have no duty to be a bailee of any such personal property. If Landlord elects to
consider such property abandoned, Tenant shall be liable to Landlord for the costs of: (i) removal of any such Work or personal property, (ii) storage, transportation, and disposition of the same, and (iii) repair and restoration of the Premises,
together with interest thereon at the Interest Rate from the date of expenditure by Landlord. In addition, if the Premises are not so surrendered at the termination of this Lease, Tenant shall indemnify Landlord against all loss or liability,
including reasonable attorneys’ fees and costs, resulting from delay by Tenant in so surrendering the Premises. 
  
 15. HOLDOVER. Tenant shall have no right to holdover possession of the Premises after the expiration or termination of this Lease without
Landlord’s prior written consent which Landlord may withhold in its sole and absolute discretion. If, however, Tenant retains possession of any part of the Premises after the Term, Tenant shall become a tenant at sufferance only, for the entire
Premises upon all of the terms of this Lease as might be applicable to such tenancy, except that Tenant shall pay all of the Base Rent, Operating Cost Share Rent and Tax Share Rent at one hundred fifty percent (150%) the rate in effect immediately
prior to such holding over (without regard to any abatements of Rent on account of a casualty or otherwise), computed on a monthly basis for each full or partial month Tenant remains in possession. Tenant shall also protect, defend, indemnify and
hold Landlord harmless from and against all Claims resulting from such failure, including, without limiting the generality of the foregoing, any claims made by any succeeding tenant founded upon such failure to surrender and any lost profits to
Landlord resulting therefrom. No acceptance of Rent or other payments by Landlord under these holdover provisions shall operate as a waiver of Landlord’s right to regain possession or any other of Landlord’s remedies. 
  
 16. SUBORDINATION TO GROUND LEASES AND MORTGAGES. 
  
 A. Subordination. This Lease shall be subordinate to any present or
future ground lease or mortgage (each a “Superior Interest”) respecting the Project, and any amendments to such ground lease or mortgage, at the election of the ground lessor or mortgagee as the case may be (each a
“Holder”), effected by notice to Tenant in the manner provided in this Lease. The subordination shall be effective upon such notice, but at the request of Landlord or such Holder, Tenant shall within ten (10) days after the request,
execute and deliver to the requesting party any reasonable documents provided to evidence the subordination. Any mortgagee has the right, at its sole option, to subordinate its mortgage to the terms of this Lease, without notice to, nor the consent
of, Tenant. With respect to any Superior Interest to which this Lease shall hereafter become subordinate, Landlord shall use commercially reasonable efforts to 
  

 27 

 obtain from the Holder of such Superior Interest, for the benefit of Tenant, a non-disturbance agreement, in the
customary form of such Holder, providing generally that as long as Tenant is not in default under this Lease, this Lease will not be terminated if such Holder acquires title to the Building or Project by reason of foreclosure proceedings, acceptance
of a deed in lieu of foreclosure, or termination of the leasehold interest of Landlord, provided that Tenant attorns to such Holder in accordance with its requirements. Except for making such commercially reasonable efforts, Landlord will be under
no duty or obligation hereunder with respect to any Superior Interest, nor will the failure or refusal of the Holder of any Superior Interest to grant a non-disturbance agreement render Landlord liable to Tenant, or affect this Lease, in any manner.
Tenant will bear all costs and expenses (including attorneys’ fees) of the Holder of such Superior Interest in connection with Landlord’s reasonable efforts to obtain a non-disturbance agreement. 
  
 B. Termination of Ground Lease or Foreclosure of Mortgage. If any
ground lease is terminated or mortgage foreclosed or deed in lieu of foreclosure given and the ground lessor, mortgagee, or purchaser at a foreclosure sale shall thereby become the owner of the Project, Tenant shall attorn to such ground lessor or
mortgagee or purchaser without any deduction or setoff by Tenant, and this Lease shall continue in effect as a direct lease between Tenant and such ground lessor, mortgagee or purchaser. The ground lessor or mortgagee or purchaser shall be liable as
Landlord only during the time such ground lessor or mortgagee or purchaser is the owner of the Project. At the request of Landlord, ground lessor or mortgagee, Tenant shall execute and deliver within ten (10) days after the request any document
furnished by the requesting party to evidence Tenant’s agreement to attorn. 
  
 C. Security Deposit. Any ground lessor or mortgagee shall be responsible for the return of any security deposit by Tenant only to the extent the security deposit, if any, is received by such ground lessor or
mortgagee. 
  
 D. Notice and Right to Cure. Tenant agrees
to send by registered or certified mail to any ground lessor or mortgagee, identified in any notice from Landlord to Tenant, a copy of any notice of default sent by Tenant to Landlord. If Landlord fails to cure such default within the required time
period under this Lease, but ground lessor or mortgagee begins to cure within ten (10) days after such period and proceeds diligently to complete such cure, then ground lessor or mortgagee shall have such additional time as is necessary to complete
such cure, including any time necessary to obtain possession if possession is necessary to cure, and Tenant shall not begin to enforce its remedies so long as the cure is being diligently pursued. 
  
 E. Definitions. As used in this Section 16, “mortgage” shall
include “trust deed” and “deed of trust”; “mortgagee” shall include “trustee”, “beneficiary” and the mortgagee of any ground lessee; and “ground lessor”, “mortgagee”, and
“purchaser at a foreclosure sale” shall include, in each case, all of its successors and assigns, however remote. 
  
 17. ASSIGNMENT AND SUBLEASE. 
  
 A. In General. Tenant shall not, without Landlord’s prior written consent in each case: (i) make or allow any assignment or transfer, by
operation of law or otherwise, of any part of Tenant’s interest in this Lease, (ii) sublet any part of the Premises, or (iii) permit anyone other than Tenant and its employees to occupy any part of the Premises (all of the foregoing are

  

 28 

 hereinafter sometimes referred to individually as a “Transfer”, and collectively as
“Transfers”, any person to whom any Transfer is made or sought to be made is hereinafter sometimes referred to as a “Transferee”, and any person by whom any Transfer is made or sought to be made is hereinafter
sometimes referred to as a “Transferor”). Tenant shall remain primarily liable for all of its obligations under this Lease, notwithstanding any Transfer. No consent granted by Landlord shall be deemed to be a consent to any
subsequent Transfer. Tenant shall pay all of Landlord’s attorneys’ fees and other expenses incurred in connection with any consent requested by Tenant or in considering any proposed Transfer. Any Transfer without Landlord’s prior
written consent shall be void. Except for a Permitted Transfer (as defined below), if Tenant shall assign this Lease or sublet or otherwise Transfer the Premises, or any portion thereof, any rights of Tenant to renew this Lease, to extend the Term
or to lease additional space in the Project shall be extinguished thereby and will not be transferred to the Transferee, all such rights being personal to the Tenant named herein. In addition, Tenant shall not, without Landlord’s prior written
consent, which Landlord may withhold in its sole discretion, mortgage, pledge or encumber this Lease, the term or estate hereby granted or any interest hereunder. 
  
 B. Landlord’s Consent. Landlord will not unreasonably withhold its consent to any proposed Transfer. It shall be
reasonable for Landlord to withhold its consent to any Transfer if (i) Tenant is in default under this Lease, (ii) the proposed Transferee is a tenant in the Project, an affiliate of such a tenant, or is negotiating with Landlord to lease space in
the Project at such time or has negotiated with Landlord during the six (6) month period immediately preceding Tenant’s request for consent, (iii) the financial responsibility, nature of business, and character of the proposed Transferee are
not all reasonably satisfactory to Landlord, (iv) in the reasonable judgment of Landlord the purpose for which the Transferee intends to use the Premises (or a portion thereof) is not in keeping with Landlord’s standards for the Building or are
in violation of the terms of this Lease or any other leases in the Project, (v) the proposed Transferee is a government entity, or (vi) the proposed Transfer is between a Transferee of Tenant (other than a Permitted Transferee) and a third party.
The foregoing shall not exclude any other reasonable basis for Landlord to withhold its consent. 
  
 C. Procedure. Tenant shall notify Landlord of any proposed Transfer at least thirty (30) days prior to its proposed effective date. The notice
shall include the name and address of the proposed Transferee, a description of the portion of the Premises that is subject to the Transfer (the “Transfer Premises”), a calculation of the Transfer Premium (as defined in Section 17.E
below) payable in connection with the Transfer, an executed copy of the proposed Transfer agreement, and sufficient information to permit Landlord to determine the financial responsibility and character of the proposed Transferee (including, without
limitation, the most recent financial statements for the proposed Transferee). As a condition to the effectiveness of any assignment of this Lease, the assignee shall execute and deliver to Landlord, at least fifteen (15) days prior to the effective
date of the assignment, Landlord’s standard form of Consent to Assignment, providing for, among other things, an assumption of all of the obligations of Tenant under this Lease. As a condition to the effectiveness of any other Transfer,
Transferee shall execute and deliver to Landlord, at least fifteen (15) days prior to the effective date of such Transfer, Landlord’s standard consent form, providing, among other things, (1) an assumption of all of the obligations of Tenant
under this Lease to the extent applicable to the Transfer Premises (excluding the payment of Rent), (2) the Transferee’s obligation to indemnify Landlord and the other Indemnitees consistent with Tenant’s indemnification obligations in
Section 8.B above, and 
  

 29 

 (3) the Transferee’s agreement that any such Transfer shall be subordinate and subject to the provisions of this
Lease, and if this Lease shall be terminated during the term of any such Transfer, Landlord shall have the right to: (a) treat such Transfer as cancelled and repossess the Transfer Premises by any lawful means, or (b) require that the Transferee
attorn to and recognize Landlord as its landlord under any such Transfer. If Tenant shall default and fail to cure within the time permitted for cure under Section 12 above, Landlord is hereby irrevocably authorized to direct any Transferee to make
all payments under or in connection with the Transfer directly to Landlord (which Landlord shall apply towards Tenant’s obligations under this Lease) until such default is cured. 
  
 D. Change of Management or Ownership. Any transfer of the direct or indirect power to affect the management or
policies of Tenant or direct or indirect change in 25% or more of the ownership interest in Tenant shall constitute an assignment of this Lease. 
  
 E. Permitted Transfers. If Tenant is not then in default of this Lease, Tenant may assign this Lease or sublet any portion of the Premises
(hereinafter collectively referred to as a “Permitted Transfer”) to (i) a parent or subsidiary of Tenant, or an entity under common control with Tenant, (ii) any successor entity to Tenant by way of merger, consolidation or other
non-bankruptcy corporate reorganization, or (iii) an entity which acquires all or substantially all of Tenant’s assets or stock (collectively, “Permitted Transferees”, and, individually, a “Permitted
Transferee”); provided that (1) at least ten (10) business days prior to the Transfer, Tenant notifies Landlord of such Transfer, and supplies Landlord with any documents or information reasonably requested by Landlord regarding such
Transfer or Permitted Transferee, including, but not limited to, copies of the sublease or instrument of assignment and copies of documents establishing to the reasonable satisfaction of Landlord that the transaction in question is one permitted
under this Section 17.E, (2) at least ten (10) business days prior to the Transfer, Tenant furnishes Landlord with a written document executed by the proposed Permitted Transferee in which such entity assumes all of Tenant’s obligations under
this Lease with respect to the Transfer Premises, (3) in the case of a Transfer pursuant to clause (ii) above, the successor entity must have a tangible net worth at the time of the Transfer (i.e., not including intangible assets in the
calculation, such as goodwill, patents, copyrights, and trademarks) computed in accordance with generally accepted accounting principles (“Net Worth”) that is at least equal to the greater of (a) the Net Worth of Tenant immediately
prior to such Transfer, or (b) the Net Worth on the date of this Lease of the original named Tenant, and (4) any such proposed Transfer is made for a good faith operating business purpose and not, whether in a single transaction or in a series of
transactions, be entered into as a subterfuge to evade the obligations and restrictions relating to Transfers set forth in this Section 17. 
  
 F. Transfer Premium. 
  
 1. If Landlord consents to a Transfer, as a condition thereto which the parties hereby agree is reasonable, Landlord shall be entitled to receive, as
Additional Rent hereunder, seventy-five percent (75%) of any Transfer Premium derived from such Transfer. As used herein, the term “Transfer Premium” means (a) in the case of an assignment, any consideration (including, without
limitation, payment for leasehold improvements) paid by the assignee on account of such assignment, and (b) in the case of any other Transfer, all rent, additional rent or other consideration paid by the Transferee to the Transferor pursuant to such

  

 30 

 Transfer in excess of the base rent and additional rent payable by such Transferor during the term of the Transfer on a
per rentable square foot basis, after deducting, on an amortized basis, without interest, over the term of the Transfer, any brokerage commissions (not to exceed commissions typically paid in the market at the time of such subletting or assignment),
reasonable attorneys’ fees paid by Tenant in connection with the Transfer and the reasonable costs of any tenant improvements (which in no event shall exceed ten dollars per square foot) paid by Tenant in connection with the Transfer
(“Recoverable Expenses”). Payment of the portion of the Transfer Premium due Landlord hereunder shall be a joint and several obligation of Tenant and the Transferee, and shall be made to Landlord as follows: (i) in the case of an
assignment, the Transferor shall pay Landlord’s portion of the Transfer Premium to Landlord within ten (10) days after the Transferor receives the Transfer Premium; and (ii) in the case of any other Transfer, on the first day of each month
during the term of the Transfer, the Transferee shall pay directly to Landlord seventy-five percent (75%) of the amount by which the rent, additional rent or other consideration due from the Transferee for such month exceeds (1) the base rent and
additional rent payable by the applicable Transferor for said month which is allocable to the Transfer Premises, plus (2) the amortized amount of Recoverable Expenses allocated to such month. No Transfer Premium shall be payable to Landlord in
connection with a Permitted Transfer. 
  
 2. Upon Landlord’s
request, Transferor shall provide Landlord with reasonable documentation of payment of the Recoverable Expenses and Transferor’s calculation of the Transfer Premium. Landlord or its authorized representatives shall have the right at all
reasonable times to audit the books, records and papers of Tenant, and any other Transferor, relating to a Transfer, and shall have the right to make copies thereof. If the Transfer Premium respecting any Transfer shall be found to be understated,
Tenant shall within ten (10) days after demand pay the deficiency, and if understated by more than two percent (2%), Tenant shall pay Landlord’s costs of such audit. 
  
 G. Recapture. In the case of a proposed assignment, sublease or other Transfer (except a Permitted Transfer) of more
than sixty percent (60%) of the rentable square footage of the Premises, Landlord may terminate this Lease as to the Transfer Premises by giving Tenant written notice (the “Recapture Notice”) within thirty (30) days after
Landlord’s receipt of the proposed fully executed Transfer agreement submitted by Tenant for Landlord’s consent. Such termination shall be effective as of the termination date set forth in Landlord’s Recapture Notice, and all
obligations of Landlord and Tenant under this Lease as to such terminated space shall expire as of such termination date, except those that expressly survive any termination of this Lease. In the event of a recapture by Landlord, if this Lease shall
be canceled with respect to less than the entire Premises, the Rent reserved herein shall be prorated on the basis of the number of rentable square feet retained by Tenant in proportion to the number of rentable square feet contained in the
Premises, and this Lease as so amended shall continue thereafter in full force and effect, and upon request of either party, the parties shall execute written confirmation of the same. 
  
 H. Tenant Remedies. Notwithstanding anything to the contrary in this Lease, if Tenant claims that Landlord has
unreasonably withheld or delayed its consent under this Section 17 or otherwise has breached or acted unreasonably under this Section 17, Tenant’s sole remedy shall be declaratory judgment and an injunction for the relief sought without any

  

 31 

 monetary damages, and Tenant hereby waives all other remedies, including, without limitation, any right provided under
California Civil Code Section 1995.310 or other applicable laws to terminate this Lease. 
  
 18. CONVEYANCE BY LANDLORD. If Landlord shall at any time transfer its interest in the Project or this Lease, Landlord shall be released of any obligations occurring after such transfer, except the obligation
to return to Tenant any security deposit not delivered to its transferee, and Tenant shall look solely to Landlord’s successors for performance of such obligations. This Lease shall not be affected by any such transfer. 
  
 19. ESTOPPEL CERTIFICATE. Each party shall, within twenty (20) days
after receiving a request from the other party, execute, acknowledge in recordable form, and deliver to the other party or its designee a certificate stating, subject to a specific statement of any applicable exceptions, that this Lease as amended
to date is in full force and effect, that Tenant is paying Rent and other charges on a current basis, and that to the best of the knowledge of the certifying party, the other party has committed no uncured defaults and has no offsets or claims. The
certifying party may also be required to state the date of commencement of payment of Rent, the Commencement Date, the Termination Date, the Base Rent, the current Operating Cost Share Rent and Tax Share Rent estimates, the status of any
improvements required to be completed by Landlord, the amount of any security deposit, and such other matters as may be reasonably requested. Tenant’s failure to execute or deliver an estoppel certificate in the required time period shall
constitute an acknowledgment by Tenant that the statements included in the estoppel certificate are true and correct, without exception. Tenant’s failure to execute or deliver an estoppel certificate or other document or instrument required
under this Section 19 in a timely manner shall be a material breach of this Lease. 
  
 20. LEASE DEPOSIT. 
  
 A.
Tenant shall deposit with Landlord on the date Tenant executes and delivers this Lease the cash sum set forth in the Schedule for the Security Deposit. The Security Deposit shall be held by Landlord as security for the faithful performance by Tenant
of all its obligations under this Lease. Tenant agrees that, if Tenant fails to pay any Rent, or otherwise defaults with respect to any provision of this Lease, Landlord may (but shall not be obligated to), and without prejudice to any other remedy
available to Landlord, use, apply or retain all or any portion of the Security Deposit for the payment of any Rent in default or for the payment of any other sum to which Landlord may become obligated by reason of Tenant’s default, or to
compensate Landlord for any loss or damage which Landlord may suffer thereby, including, without limitation, prospective damages and damages recoverable pursuant to California Civil Code Section 1951.2. Tenant waives the provisions of California
Civil Code Section 1950.7, and all other provisions of law now in force or that become in force after the date of execution of this Lease, that restrict the use or application of the Security Deposit by Landlord. If Landlord uses or applies all or
any portion of the Security Deposit as provided above, Tenant shall, within five (5) days after demand therefor, deposit cash with Landlord in an amount sufficient to restore the Security Deposit to the full amount thereof, and Tenant’s failure
to do so shall, at Landlord’s option, be a default under this Lease with no opportunity to cure. If Tenant performs all of Tenant’s obligations hereunder, the Security Deposit, or so much thereof as has not theretofore been applied by
Landlord, shall be returned to Tenant (or, at Landlord’s option, to the last 
  

 32 

 assignee, if any, of Tenant’s interest hereunder) within thirty (30) days following the expiration of the Term and
after Tenant has vacated the Premises; provided, however, that if this Lease is terminated by Landlord pursuant to Section 13 above, or by Tenant in a bankruptcy proceeding pursuant to 11 U.S.C. §365, Landlord may retain the Security Deposit
and apply the same against its damages recoverable pursuant to California Civil Code Section 1951.2. Landlord shall not be deemed to hold the Security Deposit in trust nor be required to keep the Security Deposit separate from its general funds, and
Tenant shall not be entitled to any interest on the Security Deposit. The Security Deposit shall not be construed as an advance payment of Rent nor liquidated damages, and if Landlord’s claims hereunder exceed the Security Deposit, Tenant shall
remain liable for the balance of such claims. 
  
 B. If Landlord
transfers its interest in the Project or this Lease, Landlord may transfer the Security Deposit to its transferee. Upon such transfer, Landlord shall have no further obligation to return the Security Deposit to Tenant, and Tenant’s right to the
return of the Security Deposit shall apply solely against Landlord’s transferee. 
  
 21. Intentionally omitted. 
  
 22.
NOTICES. All notices, consents, approvals and similar communications to be given by one party to the other under this Lease, shall be given in writing, mailed or personally delivered as follows: 
  
 A. Landlord. To Landlord as follows: 
  
 CarrAmerica Realty Corporation 
 1810 Gateway Drive, Suite 150 
 San Mateo,
CA 94404 
 Attn: Market Officer 
  
 with a copy to: 
  
 CarrAmerica Realty Corporation 
 1850 K
Street, N.W., Suite 500 
 Washington, D.C. 20006 
 Attn: Lease Administration 
  
 or
to such other person at such other address as Landlord may designate by notice to Tenant. 
  
 B. Tenant. To Tenant as follows: 
  
 Pericom Semiconductor Corporation 
 3545 North First Street 
 San Jose, CA 95134 
 Attn: Mike Craighead,
Chief Financial Officer 
  

 33 

 with a copy to: 
  
 Pericom Semiconductor Corporation 
 3545 North First Street 
 San Jose, CA 95134 
 Attn: Real Estate Department 
  
 or to such other person at such other address as Tenant may designate by notice to Landlord. 
  
 Mailed notices shall be sent by United States certified or registered mail, or by a reputable national overnight courier
service, postage prepaid. Mailed notices shall be deemed to have been given on the earlier of actual delivery or three (3) business days after posting in the United States mail in the case of registered or certified mail, and one (1) business day in
the case of overnight courier. Tenant hereby appoints as its agent to receive the service of process in any action, or any notice required by law to be given prior to the commencement of any action, for recovery of possession of the Premises or any
part thereof, and to receive service of all notices hereunder (including dispossessory or distraint proceedings and notices thereunder), the person in charge of or occupying the Premises at the time, and, if no person shall be in charge of or
occupying the same, then such service may be made by attaching the same on the main entrance of the Premises. 
  
 23. QUIET POSSESSION. So long as Tenant shall perform all of its obligations under this Lease, Tenant shall enjoy peaceful and quiet possession of
the Premises against any party claiming through the Landlord, subject to all of the terms of this Lease. 
  
 24. REAL ESTATE BROKERS. Tenant represents to Landlord that Tenant has not dealt with any real estate broker with respect to this Lease except for
any broker(s) listed in the Schedule, and no other broker is in any way entitled to any broker’s fee or other payment in connection with this Lease. Tenant shall indemnify and defend Landlord against any Claims by any other broker or third
party for any payment of any kind in connection with this Lease. 
  
 25. MISCELLANEOUS. 
  
 A. Successors and
Assigns. Subject to the limits on Tenant’s assignment contained in Section 17, the provisions of this Lease shall be binding upon and inure to the benefit of all successors and assigns of Landlord and Tenant. 
  
 B. Date Payments Are Due. Except for payments to be made by Tenant
under this Lease which are due upon demand or are due in advance (such as Base Rent), Tenant shall pay to Landlord any amount for which Landlord renders a statement of account within fifteen (15) days after Tenant’s receipt of Landlord’s
statement. 
  
 C. Meaning of “Landlord”,
“Re-Entry”, “including” and “Affiliate”. The term “Landlord” means only the owner of the Project and the lessor’s interest in this Lease from time to time. The words “re-entry” and
“re-enter” are not restricted to their technical legal meaning. The words “including” and similar words shall mean “without limitation.” The word “affiliate” shall mean a person or entity controlling,
controlled by or under common control with the applicable entity. “Control” shall mean the power directly or indirectly, by contract or otherwise, to direct the management and policies of the applicable entity. 
  

 34 

 D. Time of the Essence. Time is of the essence of each provision of this Lease. 
  
 E. No Option. The submission of this Lease to Tenant for review or
execution does not create an option or constitute an offer to Tenant to lease the Premises on the terms and conditions contained herein, and this Lease shall not become effective unless and until it has been executed and delivered by both Landlord
and Tenant. 
  
 F. Severability. If any provision of this
Lease is determined to be invalid, illegal or unenforceable, then such provision will be enforced to the maximum extent possible and the other provisions will remain fully effective and enforceable. 
  
 G. Governing Law. This Lease shall be governed in all respects by the
laws of the state in which the Project is located, without regard to the principles of conflicts of laws. 
  
 H. Lease Modification. Tenant agrees to modify this Lease in any way reasonably requested by a mortgagee which does not cause increased expense to
Tenant or otherwise materially adversely affect Tenant’s rights or obligations under this Lease. 
  
 I. No Oral Modification. No modification of this Lease shall be effective unless it is a written modification signed by both parties. 

 
 J. Landlord’s Right to Cure. Subject to Tenant’s grace
period and cure rights hereunder, Landlord may cure any default by Tenant; any expenses incurred shall constitute Additional Rent due from Tenant on demand by Landlord. 
  
 K. Captions. The captions used in this Lease shall have no effect on the construction of this Lease. 
  
 L. Authority. Landlord and Tenant each represents to the other that it
has full power and authority to execute and perform this Lease. 
  
 M. Landlord’s Enforcement of Remedies. Landlord may enforce any of its remedies under this Lease either in its own name or through an agent. 
  
 N. Entire Agreement. This Lease, together with all Exhibits, constitutes the entire agreement between the parties. No
representations or agreements of any kind have been made by either party which are not contained in this Lease. 
  
 O. Landlord’s Title. Landlord’s title shall always be paramount to the interest of Tenant, and nothing in this Lease shall empower Tenant
to do anything which might in any way impair Landlord’s title. 
  
 P. Light and Air Rights. Landlord does not grant in this Lease any rights to light and air in connection with Project. Landlord reserves to itself the Project, the Building below the improved floor of each floor of the Premises, the
Building above the ceiling of each floor of the Premises, and the exterior of the Premises. 
  

 35 

 Q. Singular and Plural. Wherever appropriate in this Lease, a singular term shall be construed to
mean the plural where necessary, and a plural term the singular. For example, if at any time two parties shall constitute Landlord or Tenant, then the relevant term shall refer to both parties together. 
  
 R. No Recording by Tenant. Tenant shall not record in any public
records any memorandum or any portion of this Lease. 
  
 S.
Exclusivity. Landlord does not grant to Tenant in this Lease any exclusive right except the right to occupy its Premises. 
  
 T. No Construction Against Drafting Party. The rule of construction that ambiguities are resolved against the drafting party shall not apply to
this Lease. 
  
 U. Survival. The waivers of claims or
rights, the releases and the obligations of Tenant under this Lease to indemnify, protect, defend and hold harmless Landlord and other Indemnitees shall survive the expiration or earlier termination of this Lease, and so shall all other obligations
or agreements of Landlord or Tenant hereunder which by their terms survive the expiration or earlier termination of this Lease. 
  
 V. Rent Not Based on Income. No Rent or other payment in respect of the Premises shall be based in any way upon net income or profits from the
Premises. Tenant may not enter into or permit any sublease or license or other agreement in connection with the Premises which provides for a rental or other payment based on net income or profit. 
  
 W. Building Manager and Service Providers. Landlord may perform any of
its obligations under this Lease through its employees or third parties hired by the Landlord. 
  
 X. Late Charge and Interest on Late Payments. Without limiting the provisions of Section 12.A, if Tenant fails to pay any installment of Rent or other charge to be paid by Tenant pursuant to this Lease within
five (5) business days after the same becomes due and payable, then Tenant shall pay a late charge equal to the greater of five percent (5%) of the amount of such payment or $250. In addition, interest shall be paid by Tenant to Landlord on any late
payments of Rent from the date due until paid at the rate provided in Section 2.D(2). Such late charge and interest shall constitute Additional Rent due and payable by Tenant to Landlord upon the date of payment of the delinquent payment referenced
above. 
  
 Y. Tenant’s Financial Statements. Within
ten (10) days after Landlord’s written request therefor (which may be made only in connection with a default by Tenant or a bona fide sale, financing or other similar transaction involving the Project), Tenant shall deliver to Landlord the
current audited annual and quarterly financial statements of Tenant, and annual audited financial statements of the two (2) years prior to the current year’s financial statements, each with an opinion of a certified public accountant, including
a balance sheet and profit and loss statement for the most recent prior year, all prepared in accordance with generally accepted accounting principles consistently applied; provided, however, that as long as Tenant’s financial statements are
readily available over the Internet or otherwise publicly available, Tenant shall not be obligated to deliver them to Landlord hereunder. 
  

 36 

 Z. Attorneys’ Fees. In any arbitration, quasi-judicial or administrative proceedings or any
action in any court of competent jurisdiction, brought by either party to enforce any covenant or any of such party’s rights or remedies under this Lease, including any action for declaratory relief, or any action to collect any payments
required under this Lease or to quiet title against the other party, the prevailing party shall be entitled to reasonable attorneys’ fees and all costs, expenses and disbursements in connection with such action, including the costs of
reasonable investigation, preparation and professional or expert consultation, which sums may be included in any judgment or decree entered in such action in favor of the prevailing party. 
  
 AA. Other Improvements. If portions of the Project or property
adjacent to the Project (collectively, the “Other Improvements”) are owned by an entity other than Landlord, Landlord, at its option, may enter into an agreement with the owner or owners of any of the Other Improvements to provide
(i) for reciprocal rights of access, use and/or enjoyment of the Project and the Other Improvements, provided that such rights do not unreasonably interfere with Tenant’s use, occupancy, possession or quiet enjoyment of the Premises, Building
or Project (ii) for the common management, operation, maintenance, improvement and/or repair of all or any portion of the Project and all or any portion of the Other Improvements, (iii) for the allocation of a portion of Operating Costs and Taxes to
the Other Improvements and the allocation of a portion of the operating expenses and taxes for the Other Improvements to the Project, (iv) for the use or improvement of the Other Improvements and/or the Project in connection with the improvement,
construction, and/or excavation of the Other Improvements and/or the Project, provided that such rights do not unreasonably interfere with Tenant’s use, occupancy, possession or quiet enjoyment of the Premises, Building or Project, and (v) for
any other matter which Landlord deems appropriate or necessary, provided that such rights do not unreasonably interfere with Tenant’s use, occupancy, possession or quiet enjoyment of the Premises, Building or Project. Nothing contained herein
shall be deemed or construed to limit or otherwise affect Landlord’s right to sell all or any portion of the Project or any other of Landlord’s rights described in this Lease. 
  
 26. UNRELATED BUSINESS INCOME. If Landlord is advised by its counsel at any time that any part of the payments by
Tenant to Landlord under this Lease may be characterized as unrelated business income under the United States Internal Revenue Code and its regulations, then Tenant shall enter into any amendment proposed by Landlord to avoid such income, so long as
the amendment does not require Tenant to make more payments or accept fewer services from Landlord, than this Lease provides. 
  
 27. BUILDING RENOVATIONS. It is specifically understood and agreed that Landlord has made no representation or warranty to Tenant and has no
obligation and has made no promises to alter, remodel, improve, renovate, repair or decorate the Premises, Building, or any part thereof and that no representations respecting the condition of the Premises or the Building have been made by Landlord
to Tenant except as specifically set forth herein or in the Tenant Improvement Agreement. However, Tenant hereby acknowledges that Landlord may during the Lease Term renovate, improve, alter, or modify (collectively, the
“Renovations”) the Project, the Building and/or the Premises including without limitation the parking structure, common areas, systems and equipment, roof, and structural portions of the same, which Renovations may include, without
limitation, modifying the common areas and tenant spaces to 
  

 37 

 comply with Governmental Requirements, including regulations relating to the physically disabled, seismic conditions, and
building safety and security. In connection with any Renovations, Landlord may, among other things, erect scaffolding or other necessary structures in the Building, limit or eliminate access to portions of the Project, including portions of the
common areas, or perform work in the Building, which work may create noise, dust or leave debris in the Building. Tenant hereby agrees that such Renovations and Landlord’s actions in connection with such Renovations shall in no way constitute a
constructive eviction of Tenant nor entitle Tenant to any abatement of Rent. Landlord shall have no responsibility or for any reason be liable to Tenant for any direct or indirect injury to or interference with Tenant’s business arising from
the Renovations, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or any part of the Premises or of Tenant’s personal property or improvements resulting from the Renovations or
Landlord’s actions in connection with such Renovations, or for any inconvenience or annoyance occasioned by such Renovations or Landlord’s actions. Landlord shall use commercially reasonable efforts in the performance of such Renovations
to minimize interference with Tenant’s conduct of business in the Premises and, with respect to any Renovations which require work to be performed in the Premises, Landlord shall provide Tenant with at least ten (10) days prior written notice.

  
 28. HAZARDOUS SUBSTANCES. 
  
 A. Prohibition Against Hazardous Substances. Except for (i) Hazardous
Substances set forth in the Environmental Questionnaire and Disclosure Statement and (ii) de minimis quantities of general office supplies customarily used by office tenants in the ordinary course of their business, such as copier toner, liquid
paper, glue, ink and cleaning solvents, Tenant shall not cause or permit any Hazardous Substances to be brought upon, produced, stored, used, discharged or disposed of in or near the Project unless Landlord has consented to such storage or use in
its sole discretion. Any handling, transportation, storage, treatment, disposal or use of any Hazardous Substances in or about the Project by Tenant, its agents, employees, contractors or invitees shall strictly comply with all applicable
Governmental Requirements. Tenant shall be solely responsible for obtaining and complying with all permits necessary for the maintenance and operation of its business, including, without limitation, all permits governing the use, handling, storage,
treatment, transport, discharge and disposal of Hazardous Substances. Tenant shall indemnify, defend and hold Landlord harmless from and against any Claims (including, without limitation, diminution in value of the Premises or the Project, damages
for the loss or restriction on use of leasable space or of any amenity of the Premises or the Project, damages arising from any adverse impact on marketing of space in the Project, Remedial Work, and sums paid in settlement of claims) which result
from or arise out of the use, storage, treatment, transportation, release, or disposal of any Hazardous Substances on or about the Project by Tenant or any Tenant Parties. If, as a result of any handling, transportation, storage, treatment, disposal
or use of any Hazardous Substances in or about the Project by Tenant, its agents, employees, contractors or invitees, any lender or governmental agency shall require testing for Hazardous Substances in the Premises, Tenant shall pay for such
testing. Tenant’s obligations under this Section shall survive the expiration or earlier termination of this Lease until all Claims within the scope of this Section 28.A are fully, finally, and absolutely barred by the applicable statutes of
limitations. 
  

 38 

 B. Landlord Notification. Tenant shall promptly provide Landlord with complete copies of all
documents, correspondence and other written materials directed to or from, or relating to, Tenant concerning environmental issues at the Premises or the Project, including, without limitation, documents relating to the release, potential release,
investigation, compliance, cleanup and abatement of Hazardous Substances, and any claims, causes of action or other legal documents related to same. Within twenty-four (24) hours of any unauthorized release, spill or discharge of Hazardous
Substances, in, on, or about the Premises or Project, Tenant shall provide written notice to Landlord fully describing the event. Tenant shall also provide Landlord with a copy of any document or correspondence submitted by or on behalf of Tenant to
any regulatory agency as a result of or in connection with the unauthorized release, spill or discharge. Within twenty-four (24) hours of receipt by Tenant of any warning, notice of violation, permit suspension or similar disciplinary measure
relating to Tenant’s actual or alleged failure to comply with any Governmental Requirements, Tenant shall provide written notice to Landlord. 
  
 C. Remedial Work. If, as a result of any handling, transportation, storage, treatment, disposal or use of any Hazardous Substances in or about the
Project by Tenant or any Tenant Parties, any investigation or monitoring of site conditions or any clean-up, containment, restoration, removal or remediation of Hazardous Substances (collectively, “Remedial Work”) is required under
any Governmental Requirements, then Tenant shall perform or cause to be performed the Remedial Work in compliance with Governmental Requirements or, at Landlord’s option, Landlord may cause such Remedial Work to be performed and Tenant shall
reimburse Landlord for the reasonable costs thereof within thirty (30) days after demand therefor. All Remedial Work performed by Tenant shall be performed by one or more contractors, selected by Tenant and approved in advance in writing by
Landlord, and under the supervision of a consulting engineer selected by Tenant and approved in advance in writing by Landlord. All costs and expenses of such Remedial Work shall be paid by Tenant, including, without limitation, the charges of such
contractor(s), the consulting engineer and Landlord’s reasonable attorneys’ and experts’ fees and costs incurred in connection with monitoring or review of such Remedial Work. 
  
 D. Environmental Questionnaire. Prior to execution of this Lease,
Tenant shall complete, execute and deliver to Landlord an Environmental Questionnaire and Disclosure Statement. The completed Environmental Questionnaire shall be deemed incorporated into this Lease for all purposes, and Landlord shall be entitled
to rely fully on the information contained therein. Tenant shall promptly update and resubmit to Landlord the Environmental Questionnaire if changes occur in the nature, content, handling, storage, use, treatment, transport, discharge, or disposal
of the Hazardous Substances described therein. Attached hereto as Exhibit E is a form of Environmental Questionnaire to be executed in accordance with the foregoing provision. 
  
 E. Environmental Condition of the Project. Landlord represents to Tenant that, to Landlord’s actual knowledge,
as of the date of this Lease, there are no Hazardous Substances in, on or under the Project in violation of applicable Governmental Requirements; provided, however, that if the foregoing representation is untrue, Landlord shall, as Tenant’s
sole and exclusive remedy, perform such Remedial Work as may be required by such Governmental Requirements. 
  

 39 

 F. Definition of “Hazardous Substances”. “Hazardous Substances” means
any hazardous or toxic substances, materials or waste which are or become regulated by any local government authority, the state in which the Project is located or the United States government, including those substances described in the
Comprehensive Environmental Response, Compensation and Liability Act of 1980, as amended, 42 U.S.C. Section 9601 et seq., the Resource Conservation and Recovery Act, as amended, 42 U.S.C. Section 6901 et seq., any other
applicable federal, state or local law, and the regulations adopted under these laws. 
  
 29. EXCULPATION. Landlord shall have no personal liability under this Lease; its liability shall be limited solely and exclusively to an amount which is equal to the lesser of (a) the interest of Landlord in
the Project or (b) the equity interest Landlord would have in the Project if the Project were encumbered by third-party debt in an amount equal to eighty percent (80%) of the value of the Project. In no event shall Landlord’s liability extend
to any other property or assets of Landlord, nor shall any officer, director, employee, agent, shareholder, partner, member or beneficiary of Landlord be personally liable for any of Landlord’s obligations hereunder. Further, in no event shall
Landlord be liable under any circumstances for any consequential damages or for injury or damage to, or interference with, Tenant’s business, including but not limited to, loss of profits, loss of rents or other revenues, loss of business
opportunity, loss of goodwill, or loss of use, however occurring. 
  
 30. COMMUNICATIONS AND COMPUTER LINES. Tenant may install, maintain, replace, remove or use any communications or computer wires and cables (collectively, the “Lines”) at the Project in or serving the Premises,
provided that (i) Tenant shall obtain Landlord’s prior written consent, use an experienced and qualified contractor approved in writing by Landlord, and comply with all of the other provisions of this Lease, (ii) an acceptable number of spare
Lines and space for additional Lines shall be maintained for existing and future occupants of the Project, as determined in Landlord’s reasonable opinion, (iii) the Lines therefor (including riser cables) shall be appropriately insulated to
prevent excessive electromagnetic fields or radiation, and shall be surrounded by a protective conduit reasonably acceptable to Landlord, (iv) any new or existing Lines servicing the Premises shall comply with all Governmental Requirements, and (v)
Tenant shall pay all costs in connection with the foregoing. Landlord reserves the right to require that Tenant remove any Lines located in or serving the Premises which are installed in violation of these provisions, or which are at any time in
violation of any Governmental Requirements or represent a dangerous or potentially dangerous condition. 
  
 31. OPTIONS TO EXTEND. 
  
 A. Renewal Options. Subject to the terms and conditions set forth below, Landlord hereby grants to Tenant two (2) successive options to extend the
Term of this Lease (each, a “Renewal Option”) for additional periods of five (5) years each (each, a “Renewal Term”). The second Renewal Option may be exercised only if the first Renewal Option has been duly
exercised. Each Renewal Term shall be upon the same terms, covenants and conditions of this Lease, including provisions regarding payment of Additional Rent, which shall remain payable on the terms herein set forth, except that (i) the Base Rent
payable by Tenant during such Renewal Term shall be as calculated in accordance with Section 31.C below, (ii) Tenant shall continue to possess and occupy the Premises in their existing condition, “as is” as of the commencement of such
Renewal Terms, and Landlord shall have no obligation to repair, 
  

 40 

 remodel, improve or alter the Premises, to perform any other construction or other work of improvement upon the Premises,
or to provide Tenant with any construction or refurbishing allowance whatsoever, and (iii) Tenant shall have no further rights to extend the Term of this Lease after the expiration of the second Renewal Term. 
  
 B. Exercise. To exercise each Renewal Option, Tenant must deliver an
unconditional binding notice to Landlord via certified mail or hand delivery not sooner than three hundred sixty-five (365) days nor later than two hundred ten (210) days prior to the then current Termination Date. Thereafter, the Base Rent for such
Renewal Term shall be determined pursuant to Subsection C below. Such determination shall be final and shall not be recalculated at the actual commencement of such Renewal Term. If Tenant fails to timely give its notice of exercise, Tenant will be
deemed to have waived the applicable (and any subsequent) Renewal Option. 
  
 C. Base Rent. The Base Rent payable by Tenant for the Premises during each Renewal Term shall be ninety-five percent (95%) of Market Rate (as defined below) for the Premises, valued as of the commencement of
such Renewal Term; provided, however, that in no event shall the annual Base Rent payable by Tenant for any year of the Renewal Terms be less than the annual Base Rent payable by Tenant during the twelve (12) month period immediately preceding the
commencement of such Renewal Term (without regard to any abatements of Rent on account of casualty or otherwise) (“Base Rent Floor”). As used herein, the term “Market Rate” shall mean the annual amount of Base Rent
that a willing tenant would pay, and that a willing landlord would accept, at arm’s length, for space comparable to the Premises within the Project or other comparable first class office projects in the vicinity of the Project (the
“Comparison Projects”), based upon binding lease transactions for tenants in the Comparison Projects that, where possible, commence or are to commence within six (6) months prior to or within six (6) months after the commencement of
the Renewal Term (“Comparison Leases”). Comparison Leases shall include renewal and new non-renewal tenancies, but shall exclude subleases and leases of space subject to another tenant’s expansion rights. Rental rates payable
under Comparison Leases shall be adjusted to account for variations between this Lease and the Comparison Leases with respect to: (i) the length of the Renewal Term compared to the lease term of the Comparison Leases; (ii) rental structure,
including, without limitation, rental rates per rentable square foot (including type, gross or net, and if gross, adjusting for base year or expense stop), additional rental, escalation provisions, all other payments and escalations; (iii) the size
of the Premises compared to the size of the premises of the Comparison Leases; (iv) free rent, moving expenses and other cash payments, allowances or other monetary concessions affecting the rental rate; (v) the age and quality of construction of
the Building; and (vi) leasehold improvements and/or allowances, including the amounts thereof in renewal leases, and taking into account, in the case of renewal leases (including this Lease), the value of existing leasehold improvements to the
renewal tenant. 
  
 D. Determination of Market Rate. The
Market Rate shall be determined as follows: 
  
 1. If Tenant
provides Landlord with its unconditional binding notice of exercise pursuant to Subsection B above, then, prior to the commencement of the applicable Renewal Term, Landlord shall deliver to Tenant either (a) a good faith written proposal of the

  

 41 

 Market Rate, or (b) notice that Landlord has determined in good faith that ninety-five percent (95%) of the Market Rate
is less than the Base Rent Floor and, therefore, that the Base Rent for the applicable Renewal Term shall be equal to the Base Rent Floor. Within twenty-one (21) days after receipt of Landlord’s proposal, Tenant shall notify Landlord in writing
(a) that Tenant accepts Landlord’s proposal or (b) that Tenant elects to submit the determination of Market Rate to arbitration in accordance with Subsections 31.D(2) through 31.D(4) below. If Tenant does not give Landlord a timely notice in
response to Landlord’s proposal, Landlord’s proposal of Market Rate shall be binding upon Tenant. 
  
 2. If Tenant timely elects to submit the determination of Market Rate to arbitration, Landlord and Tenant shall first negotiate in good faith in an
attempt to determine the Market Rate. If Landlord and Tenant are able to agree within thirty (30) days following the delivery of Tenant’s notice to Landlord electing arbitration (or if Tenant accepts Landlord’s initial proposal), then such
agreement shall constitute a determination of Market Rate for purposes of this Section, and the parties shall immediately execute an amendment to this Lease stating the Base Rent for the applicable Renewal Term. If Landlord and Tenant are unable to
agree on the Market Rate within such negotiating period, then within fifteen (15) days after the expiration of such negotiating period, the parties shall meet and concurrently deliver to each other in envelopes their respective good faith estimates
of the Market Rate (set forth on a net effective rentable square foot per annum basis). If the higher of such estimates is not more than one hundred five percent (105%) of the lower, then the Market Rate shall be the average of the two. Otherwise,
the dispute shall be resolved by arbitration in accordance with Subsections (3) and (4) below. 
  
 3. Within seven (7) days after the exchange of estimates, the parties shall select as an arbitrator an independent real estate broker with at least five
(5) years of experience in leasing office/R&D space in the metropolitan area in which the Project is located (a “Qualified Appraiser”). If the parties cannot agree on a Qualified Appraiser, then within a second period of seven
(7) days, each shall select a Qualified Appraiser and within ten (10) days thereafter the two appointed Qualified Appraisers shall select an independent Qualified Appraiser and the independent Qualified Appraiser shall be the sole arbitrator. If one
party shall fail to select a Qualified Appraiser within the second seven (7) day period, then the Qualified Appraiser chosen by the other party shall be the sole arbitrator. 
  
 4. Within twenty-one (21) days after submission of the matter to the arbitrator, the arbitrator shall determine the Market
Rate by choosing whichever of the estimates submitted by Landlord and Tenant the arbitrator judges to be more accurate. The arbitrator shall notify Landlord and Tenant of its decision, which shall be final and binding. If the arbitrator believes
that expert advice would materially assist him, the arbitrator may retain one or more qualified persons to provide expert advice. The fees of the arbitrator and the expenses of the arbitration proceeding, including the fees of any expert witnesses
retained by the arbitrator, shall be paid by the party whose estimate is not selected. Each party shall pay the fees of its respective counsel and the fees of any witness called by that party. 
  
 5. Until the matter is resolved by agreement between the parties or a
decision is rendered in any arbitration commenced pursuant to this Section 31, Tenant’s monthly payments of Base Rent shall be equal to the Base Rent in effect prior to the expiration of the 
  

 42 

 initial term. Within ten (10) business days following the resolution of such dispute by the parties or the decision of
the arbitrator, as applicable, Tenant shall pay to Landlord, or Landlord shall pay to Tenant, the amount of any deficiency or excess, as the case may be, in the Base Rent theretofore paid. 
  
 E. Conditions of Exercise. Notwithstanding any provision of this
Section 31 to the contrary, if Tenant is in default under this Lease (after any applicable notice and cure period) at the time it exercises either of the Renewal Options or at any time thereafter until the commencement of the applicable Renewal
Term, Landlord shall have, in addition to all of its other rights and remedies under this Lease, the right (but not the obligation) to terminate the remaining Renewal Options, if any, and to unilaterally revoke Tenant’s exercise of a Renewal
Option, in which case this Lease shall expire on the Termination Date (as the same may have been extended), unless earlier terminated pursuant to the terms hereof, and Tenant shall have no further rights to renew this Lease or extend the Term.

  
 F. Rights Personal. Tenant’s right to exercise the
Renewal Options is personal to, and may be exercised only by, the original named Tenant under this Lease or any Permitted Transferee, and only if the original named Tenant or such Permitted Transferee continues to occupy the entire Premises at the
time of such exercise. If Tenant shall assign this Lease or sublet all or any portion of the Premises under a sublease which is effective at any time during the final twelve (12) months of the initial Term to a party other than a Permitted
Transferee, then immediately upon such assignment or subletting, Tenant’s right to exercise the Renewal Options shall simultaneously terminate and be of no further force or effect. Except for a Permitted Transferee, no assignee or subtenant
shall have any right to exercise the Renewal Options granted herein. 
  
 32. RIGHT OF FIRST OFFER. 
  
 A. First Offer
Space; Exercise. Subject to the terms and conditions set forth in this Section 32, Tenant shall have the continuous right of first offer (the “Right of First Offer”) to lease the buildings in the Project commonly known as
Buildings “E” (i.e., located at 50 Rio Robles Drive) and “F” (i.e., located at 30 Rio Robles Drive), as outlined on Exhibit A-1 attached hereto (collectively, the “First Offer Buildings”), if
at any time during the Term or the Renewal Term, if applicable, the First Offer Buildings (or either of them) become available for lease to third parties. Prior to leasing either of the First Offer Buildings to a third party, Landlord shall give
notice to Tenant (an “Offering Notice”) specifying Landlord’s good faith estimate of (i) the Base Rent which Landlord proposes to charge for the applicable First Offer Building, (ii) the approximate date upon which such First
Offer Building is anticipated to be available for delivery, and (iii) any other material conditions or provisions relating to the leasing of the First Offer Building which vary from the provisions of this Lease. Tenant may exercise the Right of
First Offer only with respect to the entirety of the First Offer Building identified in any Offering Notice, and only if Tenant intends to occupy such First Offer Building in connection with its own reasonably foreseeable needs. For purposes of this
Section 32, the First Offer Building shall be “available for lease” if Landlord is free to lease the First Offer Building to the general public, unencumbered by any renewal rights or other similar rights in favor of the existing
tenant of the First Offer Building. 
  

 43 

 B. Terms and Conditions. If Tenant wishes to lease any First Offer Building on the terms specified
by Landlord in the Offering Notice and on the terms of this Section 32, Tenant shall so notify Landlord within ten (10) days after receipt thereof, which notice shall be unconditional and irrevocable. If Tenant timely exercises the Right of First
Offer, then except as specified in the Offering Notice (which shall govern to the extent of any conflict with this Lease), the First Offer Building shall become a portion of the Premises on all of the terms and conditions of this Lease for the
remainder of the Term, except that (i) the Base Rent for the First Offer Building shall be as set forth in the Offering Notice, (ii) Tenant’s Proportionate Share shall be adjusted to reflect the addition of the First Offer Building, and (iii)
the First Offer Building shall be delivered in its then-existing condition, “as is” as of the date of delivery of the First Offer Building, and Landlord shall have no obligation to repair, remodel, improve or alter the First Offer
Building, to perform any other construction or other work of improvement upon the First Offer Building, or to provide Tenant with any construction or refurbishing allowance whatsoever. Except as may be specified in the Offering Notice, Tenant shall
commence paying Base Rent and all Additional Rent with respect to a First Offer Building on the date of delivery of such First Offer Building to Tenant in the condition required hereunder. Landlord shall promptly prepare, and Landlord and Tenant
shall promptly execute, an amendment to this Lease reflecting the addition of such First Offer Building. If Tenant fails to timely notify Landlord that it wishes to lease a First Offer Building identified in any Offering Notice, or if Tenant fails
to execute and deliver said lease amendment to Landlord within ten (10) days after receipt thereof by Tenant, Landlord may thereafter lease such First Offer Building to any person on terms and conditions Landlord may deem appropriate. 
  
 C. Conditions to Exercise. Notwithstanding anything to the contrary
set forth herein, if Tenant is in default under this Lease (after any applicable notice and cure period) at the time the Right of First Offer is exercised or at any time thereafter until the delivery of a First Offer Building, or if Tenant has been
in default under this Lease (after any applicable notice and cure period) at any time prior to the exercise of the Right of First Offer, Landlord shall have, in addition to all of its other rights and remedies under this Lease, the right (but not
the obligation) to terminate the Right of First Offer and to unilaterally revoke the exercise of the Right of First Offer. If not earlier terminated, the rights of Tenant pursuant to this Section 32 shall automatically terminate upon the Termination
Date. Nothing contained in this Section 32 shall be deemed to impose any obligation on Landlord to refrain from negotiating with the existing tenant(s) of the First Offer Buildings, to withhold the First Offer Buildings from the market after Tenant
fails to timely exercise the Right of First Offer, or to take any other action or omit to take any other action, not specifically referenced in this Section 32, in order to make the First Offer Buildings available to Tenant. 
  
 D. Rights Personal to Tenant. Tenant’s right to lease the First
Offer Buildings pursuant to this Section 32 is personal to, and may be exercised only by, the original named Tenant under this Lease or any Permitted Transferee, and only if such Tenant or such Permitted Transferee continues to occupy the entire
Premises at the time of such exercise. If Tenant shall assign the Lease or sublet all or any portion of the Premises, other than to a Permitted Transferee, then immediately upon such assignment or subletting, Tenant’s right to lease any
remaining First Offer Building(s) pursuant to this Section 32 shall simultaneously terminate and be of no further force or effect. 
  

 44 

 IN WITNESS WHEREOF, the parties hereto have executed this Lease. 
  

	 LANDLORD:

	
	 CARRAMERICA REALTY CORPORATION,
 a Maryland corporation

		
	 By:
	 	  

	 	 	 Christopher Peatross

	 	 	 Managing Director

  

	 Date of Execution:
	 	  

  

	TENANT:
	
	 PERICOM SEMICONDUCTOR CORPORATION,
 a California corporation

		
	 By:
	 	  

	 Name:
	 	  

	 Title:
	 	  

	 	 	 [chairman, president or vice-president]

		
	 By:
	 	  

	 Name:
	 	  

	 Title:
	 	  

	 	 	 [secretary, assistant secretary,

	 	 	 chief financial officer or assistant treasurer]

  

	 Date of Execution:
	 	  

  

 45 

 EXHIBIT A 
  

DESCRIPTION OF PREMISES 
  
 [See Attached] 
  

 Exhibit B, Page 1 

 EXHIBIT A-1 
  
 DESCRIPTION OF FIRST OFFER SPACE 
  
 [See Attached] 
  

 Exhibit B, Page 2 

 EXHIBIT B 
  

RULES AND REGULATIONS 
  
 1. Tenant shall not place anything, or allow anything to be placed near the glass of any window, door, partition or wall which may, in Landlord’s
judgment, appear unsightly from outside of the Project. 
  
 2. The
sidewalks, exits and entrances located in the common areas of the Project shall not be obstructed by Tenant or used by Tenant for any purposes other than for ingress to and egress from the Premises. Tenant shall lend its full cooperation to keep
such areas free from all obstruction and in a clean and sightly condition and shall move all supplies, furniture and equipment as soon as received directly to the Premises and move all such items and waste being taken from the Premises (other than
waste customarily removed by employees of the Building) directly to the shipping platform at or about the time arranged for removal therefrom. 
  
 3. Tenant shall not bring upon, use or keep in the Premises or the Project any kerosene, gasoline or inflammable or combustible fluid or material, or any
other articles deemed hazardous to persons or property other than as specifically permitted in the Lease. 
  
 4. Landlord shall have sole power to direct electricians as to where and how telephone and other wires are to be introduced. No boring or cutting for
wires is to be allowed without Landlord’s prior written consent. The location of telephones, call boxes and other office equipment affixed to the Premises shall be subject to Landlord’s prior approval. 
  
 5. No additional locks shall be placed upon any doors, windows or transoms in
or to the Premises. Tenant shall not change existing locks or the mechanism thereof without prior notice to Landlord. Upon termination of the Lease, Tenant shall deliver to Landlord all keys and passes for offices, rooms, parking lot and toilet
rooms which shall have been furnished Tenant. If the keys so furnished are lost, Tenant shall pay Landlord therefor. 
  
 6. Tenant shall not install linoleum, tile, carpet or other floor covering so that the same shall be affixed to the floor of the Premises in any manner
except as approved by Landlord. 
  
 7. No furniture, packages,
supplies, equipment or merchandise will be received in the Project, except between such hours as shall be designated by Landlord. 
  
 8. Without Landlord’s prior written consent, Tenant shall not use the name of the Project or any picture of the Project in connection with, or in
promoting or advertising the business of, Tenant, except Tenant may use the address of the Project as the address of its business. 
  
 9. Tenant assumes full responsibility for protecting the Premises from theft, robbery and pilferage, which may arise from a cause other than
Landlord’s negligence, which includes keeping doors locked and other means of entry to the Premises closed and secured. 
  
 10. Peddlers, solicitors and beggars shall be reported to the office of the Project or as Landlord otherwise requests. 
  

 Exhibit B, Page 3 

 11. Tenant shall not advertise the business, profession or activities of Tenant conducted in the Project
in any manner which violates the letter or spirit of any code of ethics adopted by any recognized association or organization pertaining to such business, profession or activities. 
  
 12. Tenant shall not make or permit any noise, vibration or odor to emanate from the Premises, or do anything therein
tending to create, or maintain, a nuisance. 
  
 13. Tenant
acknowledges that Building security problems may occur which may require the employment of extreme security measures in the day-to-day operation of the Project. 
  

Accordingly: 
  
 (a) Landlord may, at any time, or from time to time, or for regularly scheduled time periods, as deemed advisable by Landlord and/or its agents, in their
sole discretion, require that persons entering or leaving the Project identify themselves to watchmen or other employees designated by Landlord, by registration, identification or otherwise. 
  
 (b) Tenant agrees that it and its employees will cooperate fully with Project
employees in the implementation of any and all security procedures. 
  
 (c) Such security measures shall be the sole responsibility of Landlord, and Tenant shall have no liability for any action taken by Landlord in connection therewith, it being understood that Landlord is not required to provide any security
procedures and shall have no liability for such security procedures or the lack thereof. 
  
 14. Tenant shall not disturb the quiet enjoyment of any other tenant. 
  
 15. Subject to the terms of the Lease, Landlord may retain a pass key to the Premises and be allowed admittance thereto at all times to enable its
representatives to examine the Premises from time to time and to exhibit the same and Landlord may place and keep on the windows and doors of the Premises at any time signs advertising the Premises for Rent. 
  
 16. No equipment, mechanical ventilators, awnings, special shades or other
forms of window covering shall be permitted either inside or outside the windows of the Premises without Landlord’s prior written consent, and then only at the expense and risk of Tenant, and they shall be of such shape, color, material,
quality, design and make as may be approved by Landlord. 
  
 17.
Tenant shall not during the term of this Lease canvas or solicit other tenants of the Building for any purpose. 
  
 18. Tenant shall not install or operate any phonograph, musical or sound- producing instrument or device, radio receiver or transmitter, TV receiver or
transmitter, or similar device in the Building, nor install or operate any antenna, aerial, wires or other equipment inside or outside the Building, nor operate any electrical device from which may emanate electrical waves which may interfere with
or impair radio or television broadcasting or reception from or in the Building or elsewhere, without in each instance Landlord’s prior written approval. The use thereof, if permitted, shall be subject to control by Landlord to the end that
others shall not be disturbed. 
  

 Exhibit B, Page 4 

 19. Tenant shall promptly remove all rubbish and waste from the Premises. 
  
 20. Tenant shall not exhibit, sell or offer for sale, rent or exchange in the
Premises or at the Project any article, thing or service, except those ordinarily embraced within the use of the Premises specified in Section 6 of this Lease, without Landlord’s prior written consent. 
  
 21. Tenant shall not overload any floors in the Premises or any public
corridors or elevators in the Building. 
  
 22. Whenever
Landlord’s consent, approval or satisfaction is required under these Rules, then unless otherwise stated, any such consent, approval or satisfaction must be obtained in advance, such consent or approval may be granted or withheld in
Landlord’s reasonable discretion, and Landlord’s satisfaction shall be determined in its sole judgment. 
  
 23. Tenant and its employees shall cooperate in all fire drills conducted by Landlord in the Building. 
  

 Exhibit B, Page 5 

 EXHIBIT C 
  

TENANT IMPROVEMENT AGREEMENT 
  
 This Tenant Improvement Agreement (“Agreement”) is an integral part of the Lease dated October 27, 2003 (“Lease”) relating to certain
Premises described therein, and except where clearly inconsistent or inapplicable, the provisions of the Lease are incorporated into this Agreement. Capitalized terms used in this Agreement not otherwise defined herein shall have the meaning given
such terms in the Lease. Landlord and Tenant agree as follows with respect to the Tenant Improvements to be installed in the Premises: 
  
 1. INITIAL TENANT IMPROVEMENTS. 
  
 (a) Landlord shall cause to be performed the initial alterations, additions and improvements (the “Tenant Improvements”) to the Premises
identified on the Space Plan attached to the Lease as Exhibit C-1 (the “Approved Space Plan”), subject to and in accordance with the notes and specifications for the Building attached hereto as Exhibit C-2 (“TI
Specifications”) which has been preliminarily priced as described on the attached Exhibit C-3. The work of constructing the Tenant Improvements is referred to as “Landlord’s Work”. 
  
 (b) Following execution of the Lease, Landlord shall cause to be prepared, at
its sole cost and expense, and delivered to Tenant final working drawings for Landlord’s Work (the “Final Plans”). The Tenant Improvements shown on the Final Plans shall be substantially consistent with those initially
identified on the Approved Space Plan. To the extent that the Final Plans are not substantially consistent with the Approved Space Plan, Tenant shall review and approve or disapprove of the Final Plans in writing within two (2) business days after
delivery. If Tenant fails to approve or disapprove the Final Plans within such two (2) business day period, Tenant shall be deemed to have approved the Final Plans. Landlord shall cause Landlord’s Work to be performed substantially as shown on
the Final Plans, excepting only minor variations (i.e., variations which are not inconsistent with the intent of the Final Plans) as Landlord may deem advisable, and any Change Orders approved by Landlord. To the extent that variations from the
Final Plan are required (other than minor variations), Landlord shall give Tenant notice of such variations and Tenant shall review and approve or disapprove (in Tenant’s reasonable discretion) such variations within two (2) business days after
notice. If Tenant fails to approve or disapprove the variations within such two (2) business day period, Tenant shall be deemed to have approved the variations. 
  

2. CHANGE ORDERS. If, prior to the Substantial Completion Date, Tenant shall request improvements or changes to the Premises in addition to, revision
of or substitution for the Tenant Improvements identified on the Approved Space Plan or the Final Plans, including, without limitation, any request for above-standard finishes or other detailed specifications not shown on the TI Specifications
attached (individually or, collectively, “Change Order Requests”), Tenant request that Landlord’s architect prepare, for Landlord’s approval, plans and specifications for such Change Order Requests. If Landlord does not
approve of the plans for such Change Order Requests, Landlord shall advise Tenant of the revisions required to approve such plans. Tenant shall revise and redeliver the plans and specifications to Landlord within five (5) days of Landlord’s
advice or Tenant shall be deemed to have abandoned its 

  

 Exhibit C, Page 1 

 
request for such Change Order Requests. If Landlord approves a Change Order Request, Landlord deliver to Tenant a statement of Landlord’s reasonable
estimate of the cost and the number of days of delay which are attributable to the Change Order Request (the “Change Order Approval”). Tenant shall approve or disapprove the Change Order Approval within two (2) business days after receipt.
If Tenant fails to approve or disapprove the Change Order Approval within such two (2) business day period, Tenant shall be deemed to have approved the Change Order Approval. 
  
 3. TENANT IMPROVEMENT COSTS. 
  
 (a) Landlord will contribute to the cost of constructing the Tenant Improvements up to One Million Five Hundred Twenty-Two Thousand Nine Hundred Dollars
($1,522,900) (the “Tenant Improvement Allowance”). Tenant shall pay all costs for the construction of the Tenant Improvements in excess of the Tenant Improvement Allowance (“Tenant’s Contribution”). The Tenant
Improvement Allowance may be applied only to the following: (A) design costs, (B) the cost of any building permits and other governmental permits, authorizations and approvals required for Landlord’s Work, and (C) other documented costs of
labor and materials incorporated into the Tenant Improvements but excluding all costs of data and telephone cabling, and all costs of furnishings, fixtures, equipment, signage and other personal property (including switches, servers, routers and
similar data and telecommunications equipment). Landlord agrees to notify Tenant of any desired overtime work and shall provide an estimate of the time savings due to such overtime work, which shall be approved or disapproved by Tenant in writing,
however, if Tenant fails to respond to Landlord’s request writing three (3) business days, Tenant shall be deemed to have approved such overtime work. Notwithstanding anything to the contrary in the Lease, Landlord and Tenant agree and
acknowledge that Landlord will be performing the construction management work in connection with the Tenant Improvements on behalf of Tenant and Landlord shall charge a management fee in connection with the construction of the Tenant Improvements,
in an amount equal to three percent (3%) of the final cost of Landlord’s Work (but in no event shall such charge exceed three percent (3%) of the Tenant Improvement Allowance). Landlord agrees to send all subcontracts out for bid, other than
mechanical, electrical, plumbing and architectural services (the “Pre-selected Vendors”) and Landlord shall provide Tenant with the bids received upon receipt. Within three (3) business days, Tenant shall select such subcontractors and
provide Landlord with notice of Tenant’s selection. If Tenant fails to select such subcontractors within such three (3) business day period, Landlord may select such subcontractors. Landlord shall pass through Landlord’s actual costs from
the Pre-selected Vendors, taking into account any discount given by such Pre-selected Vendors. Weekly during the construction of the Tenant Improvements, Landlord, Tenant, the general contractor, the subcontractors and any non-billable vendors shall
meet to review the budget and schedule. Landlord shall prepare meeting minutes summarizing the items discussed. 
  
 (b) Upon receipt by Landlord of an estimated budget for the completion of Landlord’s Work in compliance with the Final Plans and thereafter from time
to time during the performance of Landlord’s Work, Landlord may invoice Tenant for Tenant’s Contribution. Tenant shall pay to Landlord the amounts specified in any such invoices within thirty (30) days of receipt thereof. Landlord shall
have no obligation to commence or to continue construction of Landlord’s Work unless any required payments on account of Tenant’s Contribution have been paid in full within such thirty (30) day period, and any delay resulting from
Tenant’s failure to 

  

 Exhibit C, Page 2 

 
timely pay Tenant’s Contribution or any portion thereof shall be a Tenant Delay. Upon request, Landlord shall supply reasonable supporting documentation
for any such invoice, in each instance within a reasonable time following such request, but Tenant shall not be entitled to delay or withhold payment of any sums invoiced by Landlord, and payment of such sums shall not be deemed a waiver of any
right on the part of Tenant to such reasonable supporting documentation. 
  
 (iv) Within thirty (30) days following final completion of Landlord’s Work (including any punch-list items) and acceptance thereof by Tenant, or as soon thereafter as is practicable, Landlord shall deliver a
statement to Tenant showing the final cost of Landlord’s Work, the application of the Tenant Improvement Allowance and Tenant’s Contribution, and any portion of the Tenant Improvement Allowance remaining thereafter. Any objection by Tenant
to such statement, or any information reported therein, shall be deemed waived if not raised by written notice to Landlord within ten (10) days following delivery of such statement. Within thirty (30) days following delivery of such statement,
Tenant shall pay to Landlord any unpaid Tenant’s Contribution. If such statement indicates an overpayment by Tenant, Landlord shall refund such overpayment to Tenant within thirty (30) days. Tenant shall not be entitled to a credit for any
unused portion of the Tenant Improvement Allowance in the form of rent abatement or otherwise. 
  
 4. SUBSTANTIAL COMPLETION. The “Substantial Completion Date” shall be the date that (i) Landlord, its architect, engineer or construction manager determines that Landlord’s Work has been
completed, except for (1) finishing details, minor omissions, mechanical adjustments, and similar items of the type customarily found on an architectural punch-list (the “Punch-List Items”), the correction or completion of which will not
substantially interfere with Tenant’s occupancy and use of the Premises; and (2) trade fixtures, workstations, telecommunications or computer cabling or built-in furniture or equipment to be installed by Tenant (“Substantial
Completion”) and (ii) Tenant is legally permitted to occupy the Premises (as evidenced by a temporary or final certificate of occupancy, or final inspection and sign-off on the job card for Landlord’s Work, or reasonable equivalent);
provided, however, (i) if Landlord is delayed in completing Landlord’s Work or in delivering possession of the Premises to Tenant as a result of any Tenant Delay, the Substantial Completion Date shall be deemed to have occurred on the date the
Substantial Completion Date would have occurred in the absence of such Tenant Delay, as reasonably determined by Landlord or Landlord’s architect; and (ii) if Tenant takes possession and commences business operations in the Premises prior to
the Substantial Completion Date, the Substantial Completion Date shall be deemed to have occurred on the date Tenant commences business operations in the Premises. Tenant shall be responsible for and shall pay any costs and expenses incurred by
Landlord in connection with, or as a consequence of, any Tenant Delay. As used in this Lease, the term “Tenant Delay” means a delay in the completion of Landlord’s Work or the delivery of possession of the Premises to Tenant,
to the extent caused by the act, omission, neglect or failure of Tenant or any of Tenant’s agents, employees, contractors or subcontractors, including, without limitation, to the extent caused by Change Order Requests. 
  

 Exhibit C, Page 3 

 EXHIBIT C-1 
  
 APPROVED SPACE PLAN 
  
 [See Attached] 
  

 Exhibit C, Page 4 

 EXHIBIT C-2 
  
 TI SPECIFICATIONS 
  
 [See Attached] 
  

 Exhibit C, Page 5 

 EXHIBIT C-3 
  
 PRLIMINARY PRICING 
  
 [See Attached] 
  
  

 Exhibit C, Page 6 

 EXHIBIT D 
  

COMMENCEMENT DATE CONFIRMATION 
  
 THIS CONFIRMATION AGREEMENT is entered into as of
                                        
    , 20     by and between CarrAmerica Realty Corporation, a Maryland corporation (“Landlord”), and Pericom Semiconductor Corporation, a California corporation (“Tenant”),
with respect to that certain Lease dated as of October 27, 2003 (the “Lease”) respecting certain premises (the “Premises”) located in the building known as 3545 North First Street, San Jose, California. 
  
 Pursuant to Section 1.A of the Lease, Landlord and Tenant hereby confirm and
agree that the Commencement Date (as defined in the Lease) is
                                        
    , 20     and that the Termination Date (as defined in the Lease) is
                                        
    , 20    . 
  
 This Confirmation Agreement supplements, and shall be a part of, the Lease. 
  
 IN WITNESS WHEREOF, Landlord and Tenant have executed and delivered this Confirmation Agreement as of the day and year first above written. 
  

	LANDLORD:
	
	CARRAMERICA REALTY CORPORATION,
	 a Maryland corporation

		
	 By:
	 	  

	 	 	 Christopher Peatross

	 	 	 Managing Director

  

	 Date of Execution:
	 	  

  

	TENANT:
	
	PERICOM SEMICONDUCTOR CORPORATION,
	 a California corporation

		
	 By:
	 	  

	 Name:
	 	  

	 Title:
	 	  

  

	 Date of Execution:
	 	  

  
  

 Exhibit D, Page 1 

 EXHIBIT E 
  

ENVIRONMENTAL QUESTIONNAIRE 
  
 As a new tenant of the Project, answer based upon: (1) any existing or previous operations of the same kind which Tenant has conducted elsewhere, and (2)
Tenant’s plans for the new space. For each answer, specify which operation(s) you are describing. 
  
 1. Solid Waste. 
  
 a. Does the facility have an EPA Hazardous Waste generator number? 
  
 b. Does the facility produce Hazardous Waste? Other chemical waste? 
  
 c. Describe each type of waste generated (whether or not hazardous).

  
 d. If the facility produces hazardous waste, is it classified
as a large quantity generator, small quantity generator or conditionally exempt small quantity generator? 
  
 e. Are hazardous waste manifests maintained for three years on site? 
  
 f. Please identify the waste disposal contractor. 
  
 2. Wastewater. 
  
 a. Does the facility produce any “process wastewater,” meaning any wastewater that has come in contact with chemicals or other materials in
process (essentially, any discharge of water other than from sinks and toilets)? 
  
 b. If so, please describe each type of process wastewater produced. 
  
 c. Is any water discharged down the floor drains? 
  
 d. Does the facility have a permit for its wastewater discharges? 
  

3. Air Emissions. 
  
 a. Does the facility emit any chemicals or wastes into the air? 
  

b. Does the facility have an air permit? 
  
 c. Does the facility treat any of its air emissions to remove air pollutants? 
  
 d. Describe the ventilation system for the facility. 
  
 4. General. 
  
 a. Has the facility ever been charged with any violation of, or found in violation of any environmental requirements? If yes, please describe. 

 

 Exhibit E, Page 1 

 b. Are you aware of any testing of soil or groundwater to determine whether any contamination exists in
or around the facility? If so, please provide results. 
  
 c.
Please describe any hazardous materials present on site, their respective quantities and the containment measures for those materials. 
  

 Exhibit E, Page 2 

 TABLE OF CONTENTS 
  

	 	  	 	  	Page

	 1.
	  	 LEASE AGREEMENT
	  	1
			
	 2.
	  	 RENT
	  	2
			
	 3.
	  	 PREPARATION AND CONDITION OF PREMISES; TENANT’S POSSESSION; REPAIRS AND MAINTENANCE
	  	8
			
	 4.
	  	 SERVICES AND UTILITIES
	  	10
			
	 5.
	  	 ALTERATIONS AND REPAIRS
	  	10
			
	 6.
	  	 USE OF PREMISES
	  	13
			
	 7.
	  	 GOVERNMENTAL REQUIREMENTS AND BUILDING RULES
	  	15
			
	 8.
	  	 WAIVER OF CLAIMS; INDEMNIFICATION; INSURANCE
	  	16
			
	 9.
	  	 FIRE AND OTHER CASUALTY
	  	19
			
	 10.
	  	 EMINENT DOMAIN
	  	20
			
	 11.
	  	 RIGHTS RESERVED TO LANDLORD
	  	20
			
	 12.
	  	 DEFAULTS
	  	22
			
	 13.
	  	 LANDLORD REMEDIES
	  	23
			
	 14.
	  	 SURRENDER
	  	25
			
	 15.
	  	 HOLDOVER
	  	25
			
	 16.
	  	 SUBORDINATION TO GROUND LEASES AND MORTGAGES
	  	26
			
	 17.
	  	 ASSIGNMENT AND SUBLEASE
	  	27
			
	 18.
	  	 CONVEYANCE BY LANDLORD
	  	29
			
	 19.
	  	 ESTOPPEL CERTIFICATE
	  	30
			
	 20.
	  	 LEASE DEPOSIT
	  	30
			
	 21.
	  	 TENANT’S PERSONAL PROPERTY AND FIXTURES
	  	31
			
	 22.
	  	 NOTICES
	  	31
			
	 23.
	  	 QUIET POSSESSION
	  	32
			
	 24.
	  	 REAL ESTATE BROKERS
	  	32
			
	 25.
	  	 MISCELLANEOUS
	  	32
			
	 26.
	  	 UNRELATED BUSINESS INCOME
	  	35
			
	 27.
	  	 BUILDING RENOVATIONS
	  	35
			
	 28.
	  	 HAZARDOUS SUBSTANCES
	  	36
			
	 29.
	  	 EXCULPATION
	  	37
			
	 30.
	  	 COMMUNICATIONS AND COMPUTER LINES
	  	38
			
	 31.
	  	 OPTION TO EXTEND
	  	38
			
	 32.
	  	 RIGHT OF FIRST OFFER
	  	41

  

 iAMENDMENT TO THE TRANSITION AGREEMENT

 EXHIBIT 10.1 
  

	 

	  	 Keith J. Peden
 Senior Vice President                        
 Human Resources
 781.860.2380
 781.860.2912
fax
	  	 Raytheon Company
 Executive Offices
 141 Spring Street
 Lexington, Massachusetts
 02421 USA

  
 September 24, 2003 
  
 Mr. Francis S.
Marchilena 
  
 Re:    Transition
Agreement 
  
 Dear Frank: 
  
 Please accept this letter confirming the understandings we have reached with
respect to: (i) the lapse of restrictions on 20,146 shares of performance-based restricted stock; (ii) the lapse of restrictions on 50,000 shares of restricted stock that you have deferred into a trust at Mellon Bank; and (iii) your resignation as
an officer and/or director of the companies set forth on Attachment A hereto. 
  

	 	1.	Lapse of Restrictions on Performance-Based Restricted Stock: Subject to the approval of the Management Development and Compensation Committee of the Board of Directors of the
Company (the “MDCC”), the Company will recognize that the performance goals related to the lapsing of restrictions on 20,146 shares of restricted stock have been met and the restrictions on such shares shall lapse on September 24, 2003.
You have requested to use shares to satisfy any tax obligation that may arise when these shares vest on September 24, 2003. 

  

	 	2.	Lapse of Restrictions on Deferred and Unvested Shares in Mellon Trust: You have elected to defer certain shares of restricted stock into a trust at Mellon Bank. Fifty
thousand shares of such award remain unvested as of the date hereof. Twenty-five thousand shares of such award are scheduled to vest on January 26, 2004 in accordance with the vesting schedule established on the date of grant. As approved by the
MDCC, the remaining 25,000 shares will vest on September 30, 2005. 

  
  

 Page 2 
 Frank S. Marchilena 
 Transition Agreement 
  

	 	3.	Officer and Director Positions. You agree to resign, effective immediately, as an officer and/or director of the companies set forth on Attachment A hereto. You shall
execute and return a resignation letter as evidence thereof. 

  

	 	4.	Trading Window: You acknowledge that in the course of your responsibilities at the Company you may have come into contact with material non-public information and that you
may be considered an “insider” for securities law purposes. You further acknowledge that you will continue to be subject to the Company’s Insider Trading Policy and blackout periods and trading windows thereunder for three months
following your resignation as an executive officer of the Company. 

  

	 	5.	Pension: For purposes of calculation of your pension under the provisions of the Raytheon Company Pension Plan for Salaried Employees (“Plan”), you will receive age
and service recognition as if you were an active participant in the Plan through September 30, 2005. For the purpose of calculating your final average earnings under the Plan, you will be treated as continuing as an active participant through
September 30, 2005. 

  

	 	6.	Miscellaneous. This letter shall constitute an amendment to your Transition Agreement dated July 31, 2002 (including but not limited to paragraph 5 thereunder). Except as set
forth herein, all of the terms and conditions of your Transition Agreement shall remain in full force and effect and are hereby ratified and confirmed. To the extent that there are any inconsistent terms in your Transition Agreement and this
Agreement, the terms of this Agreement shall take precedence. 

  

 Page 3 
 Frank S. Marchilena 
 Transition Agreement 
  
 If you have any questions
regarding the above, please contact me at (781) 860-2380. 
  

	Sincerely,
	
	 /s/ Keith J. Peden

	

	 Keith J. Peden
 Senior Vice President, Human Resources

  

	 ACCEPTED:
	 	 	 	 
			
	 /s/ Francis S. Marchilena
	 	 	 	 Date: Oct. 22, 2003

	
	 	 	 	 
	 Francis S. Marchilena
	 	 	 	 

  

 Page 4 
 Frank S. Marchilena 
 Transition Agreement 
  
 Attachment A

  
 Directorships and Officerships as of September 24, 2003

  

	 Company

	  	 Title

		
	 Raytheon Canada Ltd.
	  	Director and Chairman
		
	 Raytheon Systems Ltd.
	  	Director
		
	 Thales-Raytheon Systems Company
 Limited
	  	Director
		
	 Thales-Raytheon Systems Company
 SAS
	  	Director
		
	 Raytheon Company
	  	 Executive Vice President
 Leader –
Discontinued Operations

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00058-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00058-of-00352.parquet"}]]