Document:

Westinghouse Purchase Agreement

 Exhibit 10.2 
 PURCHASE AGREEMENT 
 BETWEEN 

CRANWOODS-WST, LTD 
 AS SELLER 
 AND 

WEC-CRANBERRY LLC 
 AS PURCHASER 
 AUGUST 18, 2011 

 PURCHASE AGREEMENT 

THIS PURCHASE AGREEMENT (this “Agreement”) is made and entered into effective as of the 18th day of August, 2011 (the
“Effective Date”), by and between CRANWOODS-WST, LTD, a Pennsylvania limited partnership (the “Seller”) and WEC-CRANBERRY LLC, a Delaware limited liability company, and/or its nominee or assignee (the
“Purchaser”). 
 WITNESSETH: 
 WHEREAS, Seller desires to sell to Purchaser and. Purchaser desires to purchase from Seller the “Property” as hereinafter described. 

NOW, THEREFORE, for and in consideration of the premises and the mutual covenants and agreements herein contained, and other good
and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the parties hereto agree as follows: 

1. Sale of Property. Seller agrees to sell, transfer and convey to Purchaser and Purchaser agrees to purchase from Seller, in
accordance with the terms of this Agreement, all of Seller’s right, title and interest in and to the following (collectively, the “Property”): 
 a. That certain real property located in the County of Butler, State of Pennsylvania, as described on Exhibit A attached hereto and incorporated herein, together with all rights, privileges,
easements and interests appurtenant thereto, including all right, title and interest of Seller in and to any streets, alleys or rights of way which are adjacent to such land, any mineral rights or subsurface rights below such land, and any mineral
rights above such land (collectively, the “Land”); 
 b. All existing buildings and other improvements,
structures, parking facilities and fixtures (other than trade fixtures owned by the Tenant, as hereinafter defined) constructed, installed or located on the Land (collectively, the “Improvements,” and, together with the Land, the
“Premises”); 
 c. Seller’s interest as landlord under that certain Lease Agreement by and between
Seller and Westinghouse Electric Company LLC (the “Tenant”) for the Premises dated and effective as September 2, 2009 (the “Lease”); 
 d. All (i) preliminary, final and proposed building plans and specifications (including “as-built” floor plans and drawings) and tenant improvement plans and specifications related to
Seller’s improvement of the Premise, and (ii) surveys, grading plans, topographical maps, architectural and structural drawings and engineering, soils, seismic, geologic and architectural reports, studies and tests conducted or
commissioned by Seller and relating to the Premises (collectively, the “Records and Plans”); 
 e. All
contracts now or hereinafter relating to the Premises and the construction of the Improvements, executed by any architects, engineers or contractors, including all amendments, supplements and revisions thereof now or hereinafter in effect, together
with all of Seller’s rights and remedies thereunder and the benefits of all 

  
 2 

 
covenants and warranties contained therein, to the extent they are assignable (collectively, the “Contracts”); provided, however, that Seller shall not be required to deliver copies of
such items if’ such items are not in Seller’s possession or control; 
 f. All building permits.,
conditional use permits, environmental permits (including, without limitation, all DNR permits), stormwater permits, approvals and licenses, other governmental or administrative permits, licenses agreements and rights relating to the construction of
the improvements on the Premises or to the operation of the Premises, to the extent that they are assignable (collectively, the “Permits and Approvals”); provided, however, that Seller shall not be required to deliver copies of such items
if such items are not in Seller’s possession or control; and 
 g. Any unexpired third-party warranties,
guaranties and bonds, relating to the Premises, to the extent that they are assignable (collectively, the “Warranties” and, together with the Records and Plans, Contracts and Permits and Approvals, the “Intangible Property”);
provided, however, Seller shall not be required to deliver copies of such items if such items are not in Seller’s possession or control. 
 2. Purchase Price and Payment. The purchase price (the “Purchase Price”) for the Property shall be Thirty-Six Million Two Hundred Thousand and no/100 Dollars ($36,200,000.00), payable as
follows: 
 a. Initial Earnest Money Deposit. Within one (1) business day of full execution of this
Agreement, Purchaser shall deliver an earnest money deposit of One Hundred Thousand and no/100 Dollars ($100,000.00) (“Earnest Money Deposit”) to Sutton Riverside Alliance, 3839 Flatlands Avenue, Suite 208, Brooklyn, New York 11234, (the
“Title Company”), to be held in escrow with the Title Company in accordance with is Agreement and deposited in a non-interest bearing account acceptable to the Purchaser. Except as otherwise expressly set forth in this Agreement, the
Earnest Money Deposit shall be nonrefundable to Purchaser. 
 b. Payment at Closing. At Closing (as
hereinafter defined), all of the Earnest Money Deposit shall be applied to the Purchase Price and Purchaser shall pay the balance of the Purchase Price, subject to any prorations due to or from Purchaser per the terms of Section 3 below, by
cashier’s check or by federal wire transfer of funds. Any interest earned on the Earnest Money Deposit shall, at Purchaser’s option, be credited to Purchaser at Closing and applied to the Purchase Price, or returned to Purchaser.

 3. Prorations and Adjustments. The funds due at Closing pursuant to Section 2.c shall be subject to adjustment as
of 12:01 am on the Closing Date (such that items of income and expense for the Closing Date itself shall be for the account of Purchaser) in accordance with the following provisions: 

a. Real Estate Taxes. All ad valorem real estate taxes, payments-in-lieu of taxes and special assessments
(“Taxes”) imposed on the Property for the year in which the Closing occurs and which are not borne by Tenant under the Lease shall be prorated and adjusted as of the Closing Date, based upon the fiscal years of the taxing bodies levying
such taxes. Notwithstanding the foregoing, Seller represents and warrants to Purchaser that all Taxes are payable by Tenant under the Lease. 

  
 3 

 b. Income. All rental and other income payable under the Lease shall
be prorated as of the Closing Date. Purchaser shall use commercially reasonable efforts after the Closing to attempt to collect any delinquent or other rental and reimbursable charges and other expense arrearages attributable to the period prior to
the Closing, but Purchaser shall not be required to commence any legal actions to do so. If either Purchaser or Seller should receive any revenues attributable to the period during which it is not the owner of the Property, said party shall forward
such amounts to the other party or, if such revenues are only partially attributable to period during which said party is not the owner of the Property, the amount to be paid to the other party shall be based upon a proration as of the Closing Date
as set forth above. 
 c. Closing Costs. Seller shall pay: (i) the cost of recording any instruments
required to discharge any liens or encumbrances against the Property which Seller is obligated to discharge pursuant to this Agreement; (ii) the cost of preparation of the deed; (iii) any fees and expenses of Seller’s attorneys;
(iv) any brokerage commissions payable to Seller’s Broker pursuant to Section 17 hereof; (v) any brokerage commissions payable to MSR Broker pursuant to Section 17 hereof; (vi) one half (1/2) of all state, county
and municipal documentary and transfer taxes and related surtax related in any manner to the transactions contemplated hereby; and (vii) one half (1/2) of all customary escrow or closing fees charged by the Title Company. Purchaser shall
pay: (vii) the costs of the Title Commitment and the premium for the Owner’s Policy and a mortgage policy, if applicable, and any endorsements to the foregoing; (viii) the costs of the Survey; (ix) (i) the recording fee for
the special warranty deed; (x) the costs of Purchaser’s tests and inspections of the Property; (xi) one half (1/2) of all state, county and municipal documentary and transfer taxes and related surtax related in any manner to the
transactions contemplated hereby; (xii) one half (1/2) of all customary escrow or closing fees charged by the Title Company; and (xiii) all fees and expenses of Purchaser’s attorneys. In the event that Purchaser assigns its
contractual rights under this Agreement to a third party prior to Closing, any and all state, county and municipal documentary or real estate transfer tax assessed in connection with the Purchaser’s assignment of the Agreement shall be borne
solely by Purchaser. The foregoing allocations shall survive the Closing or earlier termination of this Agreement. Notwithstanding anything to the contrary set forth in this Section 3.c., and subject only to the provisions of Section 18
hereof, in the event that Closing does not occur pursuant to this Agreement, Seller shall be entitled to reimbursement from Purchaser of any and all sums theretofore paid by Seller in connection with item (v) above; all of which sums shall be
paid to Seller by Purchaser exclusive of, and in addition to, any other applicable damages or recourse available to Seller pursuant to Section 18 hereof. In the event that Purchaser is entitled to a return of the Deposit pursuant to this
Agreement notwithstanding the failure of the parties to proceed to Closing hereunder, Seller shall, prior to any such return of the Deposit to Purchaser and subject only to the terms set forth at Section 18 hereof, be entitled to payment of
that portion of the Deposit equal to all amounts to be reimbursed to Seller in accordance with this Section 3.c. Notwithstanding anything to the contrary set forth in this Agreement, Purchaser shall pay to Seller, at Closing and in addition to
the 

  
 4 

 
Purchase Price, any additional amounts incurred by Seller due to the increase in the Purchase Price as a result of Seller’s obligation to pay any brokerage commissions to MSR Broker,
including without limitation any and all additional state, county and municipal documentary and transfer taxes, and any additional brokerage commissions, paid by Seller as a result of such increase. 

d. Estimates and Errors. If any of the items to be adjusted at the Closing pursuant to this Section 3 cannot
be adjusted accurately because of the unavailability of the amounts which are subject to adjustment, such items shall be adjusted on the basis of a good faith estimate by the parties and reconciled as soon as practicable after the Closing Date;
provided, however, all such reconciliations shall occur no later than one (1) year after the Closing Date. If any party discovers any error in any closing adjustments within one (1) year after the Closing Date, the parties shall make such
further adjustments and reconciliations as are necessary to correct and reconcile such errors; provided, however, all such adjustments and reconciliations shall occur no later than one (1) year after the Closing Date. The parties’
obligations under this Section 3(d) shall survive the Closing. 
 4. Representations, Warranties and Covenants of
Seller. Seller hereby represents and warrants to Purchaser as of the Effective Date and as of the Closing Date that: 
 a. Seller has full and lawful right and authority to execute and deliver this Agreement and to consummate the transactions contemplated hereunder. 

b. The execution of this Agreement and all documents and instruments executed pursuant to this Agreement by Seller, the
delivery thereof to Purchaser, Seller’s performance hereof and the transactions contemplated hereby have been duly authorized by all requisite action on the part of Seller a id do not conflict with or result in a violation of any judgment,
order or decree of any court or proceeding to which Seller is a party, and all such documents are valid and binding obligations of Seller and are enforceable in accordance with their terms. 

c. Seller has not (i) made a general assignment for the benefit of creditors, (ii) filed any voluntary petition
in bankruptcy or suffered the filing of any involuntary petition by Seller’s creditors, (iii) suffered the appointment of a receiver to take possession of the Property or all, or substantially all, of Seller’s other assets,
(iv) suffered the attachment or other judicial seizure of any of the Property o: all, or substantially all, of Seller’s other assets, (v) admitted in writing its inability to pay its debts as they come due or (vi) made an offer
of settlement, extension or composition to its creditors generally. 
 d. Seller is duly organized and validly
existing and in good standing under the laws of its state of its formation. Seller further represents and warrants that this Agreement and all documents executed by Seller that are to be delivered to Purchaser at the Closing: (i) are, or at the
time of such Closing will be, duly authorized, executed and delivered by Seller, (ii) do not, and at the time of the Closing, will not, violate any provision of any agreement or order to which Seller is a party or to which Seller or the
Property is subject, and (iii) constitute (or in the case of documents executed by Seller that are to be delivered to Purchaser will constitute) a valid and legally binding obligation of Seller, enforceable in accordance with its terms.

  
 5 

 e. There is currently no litigation, bankruptcy or other proceeding pending
in any manner affecting the Property. 
 f. Seller has not received any written notice from any person or
governmental authority regarding any pending or threatened condemnation of the Property or any part thereof and to Seller’s knowledge, there is no pending or threatened condemnation of the Property or any part thereof. 

g. Other than the Lease and the Permitted Exceptions (as hereinafter defined), there are no contracts or agreements
affecting the Property that will be binding on Purchaser or the Property from and after the Closing. No security deposits are held by or on behalf of Seller on account of the Lease. 

h. Seller has not received written notice of any litigation that is pending or threatened with respect to the Property and
to Seller’s knowledge there is no litigation that is pending or threatened with respect to the Property. 

i. Seller has not received any notice from any person or governmental authority that all or any portion of the Property is
in violation of any applicable order, building codes or any applicable environmental law (relating to clean-up or abatement), zoning law or land use law, or any other applicable local, state or federal law or regulation relating to the Property and,
to the best of Seller’s knowledge, no such violations exist. The zoning of the Property permits the improvements on the Premises and the use of the Property under the Lease and there is no pending rezoning. 

j. Except for Tenant’s right of first offer (as described at Section 11.1.1. hereof), Seller has not granted any
option or right of first refusal or first opportunity to any party to acquire any fee interest in any portion of the Property. 
 k. To the Seller’s knowledge,: (A) the Property is now free from contamination by Hazardous Materials (as hereinafter defined), the Property and the activities conducted thereon as of the
Effective Date and as of the date of the Closing do not violate any law, and there is no evidence of a release of Hazardous Materials at the Property; (B) there has been no generation, treatment, or storage of any Hazardous Materials at the
Property nor any activity at the Property which could have produced Hazardous Materials; (C) there are no surface impoundments, lagoons, waste piles, landfills, injection wells, underground storage areas, tanks, storage vessels, drums,
containers, or other man-made facilities at the Property which may have accommodated Hazardous Materials at the Property; (D) neither Seller nor anyone else has stored, placed, buried, or released Hazardous Materials at the Property;
(E) there has been no treatment, storage, or release of any Hazardous Materials on land adjacent or near to the Property’, (F) no inspection, audit, inquiry, or other investigation has been or is being conducted by anyone with respect
to the presence or discharge of Hazardous Materials at the Property; (G) Seller has not received notice that any such inspection, audit, inquiry, or 

  
 6 

 
investigation is pending or proposed; and (H) neither Seller nor, to the Seller’s knowledge, any previous owner of the Property has received any warning, notice, notice of violation,
administrative complaint, judicial complaint, or other form or informal notice or request for information alleging that Hazardous Materials have been stored or released at the Property, that conditions at the Property are in violation of any law, or
requesting information regarding the use, storage, release, or potential release of Hazardous Materials at the Property. “Hazardous Materials” shall mean materials, wastes or substances that are (A) included within the definition of
any one or more of the terms “hazardous substances”, “hazardous materials”, “toxic substances”, “toxic pollutants” and “hazardous waste” in the Comprehensive Environmental Response, Compensation and
Liability Act of 1980, as amended (42 U.S.C. Sections 9601, et seq.), the Resource Conservation and Recovery Act of 1976 (42 U.S.C. Section 6901, et seq.), the Clean Water Act (33 U.S.C. Section 1251, et seq.), the Safe Drinking Water Act
(14 U.S.C. Section 1401; et seq.), the Hazardous
Materials Transportation Act (49 U.S.C. Section 1801, et seq.), and the Toxic Substance Control Act (15 U.S.C. Section 2601, et seq.) and the regulations promulgated pursuant to such laws, (B) regulated, or classified as hazardous or
toxic, under federal, state or local environmental laws or regulations, (C) petroleum, (D) asbestos or asbestos-containing; materials, (E) polychlorinated biphenyls, (F) flammable explosives or (G) radioactive materials;
provided, however, that the representations and warranties set forth in this Section 4.k. shall be subject to, and shall not be in any manner applicable to: (i) such conditions as are revealed or otherwise set forth in that certain
“Phase I Environmental Site Assessment Report Lot 3 In Cranberry Woods Office Park, Cranberry Township, Butler County, Pennsylvania”, dated August 11, 2009, prepared by Civil & Environmental Consultants, Inc. and identified
as CEC Project 090-527.0009; which Report shall be delivered to Purchaser as part of the Documents (as hereinafter defined); (ii) such quantities of Hazardous Materials maintained at the Property in compliance, in all material respects, with
applicable law and which are reasonably necessary for Seller’s or Seller’s tenant’s operations at the Property; and/or (iii) those conditions to be set forth on Exhibit G hereof. 

l. There are no maintenance, service or other contracts relating to the operation of the Property in Seller’s name
which will become the obligation of Purchaser upon the Closing. 
 m. Seller and Tenant, as applicable, have all
licenses, approvals, permits, easements, and rights of way, including proof of dedication, building permits, and occupancy permits that are required from any governmental authority having jurisdiction over the Property or from private parties, in
order to operate the improvements on the Premises in accordance with the Records and Plans and to use the Property as contemplated in the Lease and to ensure adequate vehicular and pedestrian access to the Property; 

n. There are no unpaid or partially paid bills outstanding for work done to the Property by or on behalf of Seller, nor
are there any mechanic’s liens claimed or filed against the Property in connection with said work except as may otherwise constitute Permitted Exceptions. Seller has received no written notice of any mechanic’s liens to be filed against
the Property. 

  
 7 

 o. All utility services to the Property are in the name of Tenant, and all
utility charges in connection therewith, are payable by Tenant under the Lease. 
 p. Except as otherwise
disclosed by virtue of the Estoppel Certificate (as defined at Section 11.1.g. hereof (i) The Lease sets forth the entire agreement between Seller and Tenant with respect to the Property; (ii) the Lease is in full force and effect and
has not been amended, modified or assigned except as disclosed in writing to Purchaser; (iii) Tenant has accepted possession of the Property and presently occupies it, and is paying rent on a current basis; (iv) no rentals or other amounts
payable under the Lease are accrued or unpaid by Tenant; (v) Seller, and to the best knowledge of Seller, Tenant, are not in default in the performance of the Lease, and have not committed any breach of the Lease which has not been cured, nor
has any event occurred which, with the passage of time or the giving of notice, or both, would constitute a current default or breach by Landlord or tenant as applicable; and (vi) no notice of default has been sent or received by Landlord.

 Whenever the term “Seller’s knowledge” is used in this Section 4, such term shall be deemed to refer
solely to the actual knowledge of Martin L. Herman. The term “Seller’s knowledge” shall mean such knowledge that actually exists as of the Effective Date, and shall not be deemed to impose upon the Seller any duty to investigate,
inquire or conduct any due diligence with respect to the representation or warranty to which such term relates; provided however, Seller represents and warrants to Purchaser that such individual is the person most knowledgeable within the
organization of Seller as to the matters set forth herein. 
 Purchaser acknowledges and agrees that, except as otherwise
expressly set forth in this Section 4, the Property is to be sold to and accepted by Purchaser “as is” and “where is,” with all faults, if any, and Seller does hereby disclaim any and all, and makes no representations or
warranties, express or implied of any kind to Purchaser, including, without limitation, warranties relating to the physical condition or habitability of the Property, the habitability of the Property, its suitability for any particular purpose, or
otherwise relating to the title of the Property. Purchaser covenants, represents and warrants that (i) Purchaser shall, as of Closing inspected or shall have had the right to inspect the Property and all matters relating thereto which Purchaser
desires; (ii) neither Seller nor anyone on Seller’s behalf has made, or is making, any warranties or representations respecting the Property other than those expressly set forth in this Section 4; and (iii) except for the
representations and warranties expressly set forth in this Agreement, Purchaser is relying solely on its own investigation of the Property and all matters pertaining thereto, including but not limited to its environmental condition. 

All representations and warranties of Seller, as set forth in this Section 4, shall survive the Closing and conveyance of title to
the Property for a period of one (1) year, but only as to the status of facts existing as of the time of Closing, it being understood that Seller has made no representation or warranty that applies to changes or other matters occurring after
the Closing Date. All such representations and warranties shall be deemed repeated on the Closing Date; provided, however, that if Purchaser shall actually discover prior to Closing that any of the representations set forth by Seller herein were
untrue when made, or have become untrue prior to Closing, then, if Purchaser shall proceed with the consummation of the purchase and sale of the Property pursuant to this Agreement, Purchaser shall be deemed to have waived any claim of

  
 8 

 
breach that Purchaser may have against Seller with respect to any such representation set forth herein. Purchaser shall promptly notify Seller if Purchaser becomes aware that any of the
representations or warranties which Seller has made in this Agreement shall be or become untrue or misleading in any respect. 

5. Representations, Warranties and Covenants of Purchaser. The Purchaser hereby represents and warrants to Seller as of the
Effective Date and as of the Closing Date that: 
 a. Purchaser has full and lawful right and authority to
execute and deliver this Agreement and to consummate the transactions contemplated hereunder. 
 b. The execution
of this Agreement and all documents and instruments executed pursuant to this Agreement by Purchaser, the delivery thereof to Seller, Purchaser’s performance hereof and the transactions contemplated hereby have been duly authorized by all
requisite action on the part of Purchaser and do not conflict with or result in a violation of any judgment, order or decree of any court or proceeding to which Purchaser is a party and all such documents are valid and binding obligations of
Purchaser and are enforceable in accordance with their terms. 
 c. Purchaser is duly organized and validly
existing and in good standing under the laws of its state of its formation. Purchaser further represents and warrants that this Agreement and all documents executed by Purchaser that are to be delivered to Seller at the Closing: (i) are, or at
the time of such Closing will be, duly authorized, executed and delivered by Purchaser, (ii) do not, and at the time of the Closing will not, violate any provision of any agreement or order to which Purchaser is a party or to which Purchaser is
subject, and (iii) constitute (or in the case of documents executed by Purchaser that are to be delivered to Seller will constitute) a valid and legally binding obligation of Purchaser, enforceable in accordance with its terms. 

All representations and warranties of Purchaser, as set forth in this Section 5, shall survive the Closing and conveyance of tile to
the Property for a period of one (1) year, but only as to the status of facts existing as of the time Closing, it being understood that Purchaser has made no representation or warranty that applies to changes or other matters occurring after
the Closing Date. All such representations and warranties shall be deemed repeated on the Closing Date; provided, however, that if Seller shall actually discover prior to Closing that any of the representations set forth by Purchaser herein were
untrue when made, or lave become untrue prior to Closing, then, if Seller shall proceed with the consummation of the purchase and sale of the Property pursuant to this Agreement, Seller shall be deemed to have waived any claim of breach that Seller
may have against Purchaser with respect to any such representation set forth herein. Seller shall promptly notify Purchaser if Seller becomes aware that any of the representations or warranties which Purchaser has made in this Agreement shall be or
become untrue or misleading in any respect. 
 6. Reserved. 

7. Due Diligence Investigation of the Property. From and after the Effective Date, Seller grants to Purchaser and its agents and
representatives the right to access the Property; and 

  
 9 

 
Purchaser may, at its sole cost and expense through. its agents and representatives, conduct a physical inspection of the Property including, without limitation, environmental and hazardous waste
and substance investigations, and such other engineering and mechanical inspections and investigations as Purchaser may reasonably require; all of which inspections and related activities shall be performed by Purchaser in accordance with, and
subject to the terms and conditions of, that certain License Agreement to be executed by Purchaser contemporaneously herewith (as attached hereto as Exhibit C and made a part hereof, the “License Agreement”). In the event that the
parties do not consummate Closing hereunder, then, upon Seller’s written request, Purchaser shall provide Seller, without representation or warranty whatsoever, with copies of the final versions of any third party reports or tests, including
without limitation the Title Commitment, Survey, (as such
terms are defined below) and any and all written reports obtained in connection with the, investigations performed by Purchaser pursuant to this Section 7; which obligation of Purchaser shall survive the termination or expiration of this
Agreement. 
 8. Title and Survey. 

a. Purchaser, at Purchaser’s expense, shall obtain a commitment for title insurance (the “Commitment”)
covering i he Premises, issued by the Title Company, committing; to issue an ALTA owner’s title policy for the Property to Purchaser at Closing. Purchaser may obtain a survey of the Property, certified to Purchase r and such other parties as
Purchaser deems appropriate, prepared and sealed by a licensed surveyor or engineer (the “Survey”). 

b. Purchaser shall have until the date that is twenty (20) days following the Effective Date (the “Title
Contingency Date”) within which to review the Commitment and any Survey, and to deliver to Seller in writing such objections (collectively, Purchaser’s “Title Objections”) as Purchaser may have to any monetary liens and
encumbrances applicable to the Property, such as mortgages, judgment, liens for delinquent real estate taxes, attachments, lien claims or other liens or encumbrances of a definite and ascertainable amount which may be removed by the payment of money
(collectively, “Monetary Encumbrances”). All items or conditions set forth or otherwise contained in the Title Commitment and/or Survey, except for such Monetary Encumbrances, shall be “Permitted Exceptions” (herein so called)
for purposes of this Agreement, it being acknowledged and agreed by Purchaser that Seller shall have no obligation to cure any items or conditions set forth or otherwise contained in the Title Commitment and/or Survey except with regard to any
applicable Monetary Encumbrances that Seller is obligated to discharge, satisfy or release pursuant to Section 12.1.b. of this Agreement. In the event hat Seller is obligated to discharge, satisfy or release any Monetary Encumbrances pursuant
to this Agreement, then Seller shall have the option to extend the Closing for up to thirty (30) business days in order to allow Seller to effectuate such cure (the “Title Cure Period”). 

c. If the title policy or an updated Commitment or Survey, as of the Closing Date, discloses additional material
non-monetary restrictions or limitations which have arisen or been placed of record not due to Seller’s actions subsequent to Purchaser’s review of the Commitment as provided for in subsection (b) above, and Purchaser objects to any
such restrictions or limitations, then Purchaser shall give written notice thereof to 

  
 10 

 
Seller within five (5) days of obtaining knowledge thereof. Seller may, but shall not be obligated, to cure any such restriction or limitation, and Seller shall have the option to extend the
Closing for the Title Cure Period in order to allow Seller to effectuate such cure. Should Seller not elect to cure prior to Closing or within the Title Cure Period, then Purchaser, by reason thereof, may cancel this Agreement by giving written
notice thereof to Seller to such effect, and upon the giving of such notice, the Earnest Money Deposit shall be refunded to Purchaser, and thereupon this Agreement shall become null and void and of no further force or effect. 

9. Reserved. 
 10. Closing. 
 a. Closing Date. The closing (the
“Closing”) of the purchase and sale of the Property shall take place through mail with the Title Company acting as escrow agent, or at such other place as shall be agreed by the parties, and shall occur on the later of: (i) the date
that is sixty (60) calendar days after the Effective Date:, (ii) the expiration of the Title Cure Period; or (iii) the date that is five (5) business days after Purchaser’s receipt of the Estoppel Certificate (as hereinafter
defined) and the SNDA (such date, or such other date as shall be agreed by the parties, or as shall be established by extension pursuant to Section 10.b. below, being designated as the “Closing Date”). Notwithstanding the foregoing,
Purchaser shall have the option to extend the Closing Date for thirty (30) calendar days (“Closing Date Extension”) by providing written notice to Seller of its election to extend the Closing Date and depositing with the Title Company
an extension deposit of Fifty Thousand and no/100 Dollars ($50,000.00); which extension deposit shall be treated as part of the Earnest Money Deposit for all purposes under this Agreement. 

b. Financing Extension. Purchaser shall be entitled to extend the Closing Date, pursuant to the terms and
conditions set forth in this Section 10.6. for four (4) consecutive periods of thirty (30) calendar days each (each, a “Financing Extension Period”), solely for the purpose of procuring its acquisition financing for the
Property (the “Financing”); provided, however, that each such extension of the Closing Date shall be effective only upon: (a) Purchaser’s provision of written notice of such extension to the Seller prior to the then-scheduled
Closing Date; and (b) Purchaser’s payment to Seller of the amount of Fifty Thousand and 00/100 Dollars ($50,000.00) prior to each such extension (each an “Extension Fee”); provided, however, that no such Extension Fee shall be
due from Purchaser in connection with the first such extension of the Closing Date. Notwithstanding the foregoing, Purchaser’s right to extend the Closing Date pursuant to this Section 10.b. shall be limited solely to an event where
Purchaser’s lender is then unable or unwilling to extend the Financing; it being agreed by Seller that, except as otherwise expressly set forth in this Agreement, all other contingencies to Closing, of every type or nature, shall be deemed
completed and satisfied as of the Effective Date. Except as otherwise specifically set forth in this Agreement, all Extension Fees shall be treated as part of the Earnest Money for all purposes under this Agreement. Buyer hereby agrees to pursue the
Financing in good faith and with all reasonable diligence. In the event that at any time Purchaser exercises its right to a Closing Date Extension pursuant to Section 10.a above, Purchaser shall only be entitled to exercise a total of three
(3) Financing Extension Periods in addition to the Closing Date Extension. 

  
 11 

 c. Possession. At Closing, Seller shall deliver possession of the
Property to Purchaser in such condition as shall be expressly required pursuant to this Agreement. 
 d.
Miscellaneous Closing Documents. In addition to such documents as shall be delivered by Seller in accordance with Section 11.1 hereof, Seller shall reasonably cooperate with Purchaser in delivering any other documents reasonably required
by the Title Company to be delivered by Seller, or necessary to implement and effectuate the Closing hereunder, including, without limitation, documents, consents and approvals from Seller, in commercially-reasonable form satisfactory to Purchaser.

 e. Failure to Close. Except as otherwise expressly set forth in this Agreement (including, without
limitation pursuant to Section 18 hereof), in the event that the parties fail to consummate Closing hereunder, then, effective as of the day following the Closing Date, this Agreement shall be deemed terminated and of no further force or
effect, the Earnest Money Deposit shall be paid to Seller, and both parties shall be released from all further obligations under this Agreement that are not otherwise expressly made to survive such termination. 

11. Closing Obligations. 
 11.1. Seller’s Obligations at Closing. At Closing, Seller shall, in addition to any other obligations of Seller as set forth in this Agreement, deliver or cause to be delivered to Purchaser,
the following items, all of which shall be duly executed and acknowledged in recordable form, where appropriate: 

a. Deed. A special warranty deed conveying fee simple title to the Property to Purchaser subject only to:
(i) taxes for the year of Closing, assessments, improvement liens and similar matters to be prorated between the parties at Closing; (ii) rights of parties in possession under the Lease; (iii) any matters created by or with the
written consent of Purchaser; and (iv) such other matters not listed above as may constitute Permitted Exceptions:, 
 b. Assignment and Assumption of the Lease. A counterpart of an assignment and assumption of the Lease, in substantially the form attached hereto as Exhibit D; 

c. Bill of Sale and Assignment. A counterpart of a bill of sale and assignment conveying title, and otherwise
assigning; Seller’s interest, in and to the Intangible Property to Purchaser, in substantially the form attached hereto as Exhibit E; 
 d. Releases. Written release of any liens security interests, UCC financing statements, mortgages or deed of trust, mechanic’s liens or other encumbrances affecting the Property that do not
constitute Permitted Exceptions, as expressly required of Seller pursuant to Section 8 hereof; 

  
 12 

 e. Seller’s Affidavit. A Seller’s Affidavit customarily
used by the Title Company, covering parties in possession and mechanic’s liens; 
 f. Non-Foreign Seller
Affidavit. An affidavit of Seller in form and substance satisfactory to Purchaser setting forth Seller’s United States taxpayer identification number and certifying that Seller is not a foreign person as that term is used and defined in
Section 1445 of the United States Internal Revenue Code; 
 g. Original Estoppel Certificate. An
original of an estoppel certificate from Tenant, dated no more than thirty (30) days prior to the Closing Date, in such form as shall be reasonably approved by Purchaser and Purchaser’s lender (the “Estoppel Certificate”);

 h. Original SNDA. An original of a Subordination Non-Disturbance and Attornment Agreement, in such form
as shall be reasonably approved by Purchaser and Purchaser’s lender (the “SNDA”); 
 i.
Original Lease. An original of the Lease, Lease Amendment and Guaranty (as hereinafter defined); 
 j.
Proof of Insurance. A Certificate of Insurance from Tenant naming Purchaser and Purchaser’s lender as an additional insured on the policies of insurance required to be carried by Tenant pursuant to the Lease and otherwise in a form
reasonably approved by Purchaser and its lender (the “Insurance Certificates”); 
 k. Intangible
Property. Original versions of the Intangible Property, to the extent in Seller’s possession or control: 
 l. Waiver. An original of waiver, executed by Tenant, of that certain right of first offer afforded to Tenant pursuant to Section 45 of the Lease (the “Waiver”); 

m. Notice to Tenant. A notice letter to Tenant advising Tenant of the assignment of the Lease; and 

n. Guaranty. A guaranty agreement, in the form attached hereto as Exhibit F or such other form as shall
be approved by Purchaser and Purchaser’s lender, pursuant to which the Tenant’s obligations under the Lease shall, as of Closing, be guaranteed by Westinghouse Electric UK Holdings Limited and TSB Nuclear Energy USA Group, Inc. (the
“Guaranty”); 
 o. Amendment to Lease. An amendment to the Lease, in such form as shall be
approved by Purchaser and Purchaser’s lender, pursuant to which: (i) the base rent payable by Tenant under the Lease shall be adjusted; (ii) the Guaranty shall be incorporated and acknowledged; and (iii) Tenant’s Waiver
shall be incorporated and acknowledged (the “Lease Amendment”); and 

  
 13 

 11.2. Purchaser’s Obligations at Closing. At Closing, Purchaser shall, in
addition to any other obligations of Purchaser as set forth in this Agreement, deliver or cause to be delivered to Seller, the following items, all of which shall be duly executed and acknowledged in recordable form, where appropriate: 

a. Purchase Price. The balance of the Purchase Price (less the Earnest Money Deposit) to Seller by cashier’s
check or by federal wire transfer (subject to adjustment and proration as hereinbefore provided); 
 b.
Assignment and Assumption of Lease. A counterpart of the assignment and assumption of the Lease, in substantially the form attached hereto as Exhibit D; 

c. Bill of Sale and Assignment. A counterpart of a bill of sale and assignment conveying title, and otherwise
assigning, Seller’s interest, in and to the Personal Property arid Intangible Property to Purchaser in the form attached hereto as Exhibit E; and 
 d. Miscellaneous. Any other documents required by this Agreement or the Title Company to be delivered by Purchaser or necessary to implement and effectuate the Closing hereunder, including, without
limitation, documents, consents and approvals from Purchaser satisfactory to Seller. 
 12. Closing Conditions.

 12.1. Conditions Precedent to Purchaser’s Obligations. Unless all of the following conditions are timely
satisfied (or waived by Purchaser in its sole discretion), then a condition precedent to Purchaser’s obligations under this Agreement shall have failed: 
 a. Seller’s Delivery of Closing Documents. Each of the documents required to be delivered by Seller pursuant to Section 11.1 shall have been timely delivered as provided therein;

 b. Title Cure. Seller shall have discharged, satisfied or released, on or prior to Closing, at
Seller’s sole cost and expense, all Monetary Encumbrances; 
 c. Representations, Warranties and
Covenants of Sellers. Seller’s representations and warranties, as set forth at Section 4, shall be true and correct in all material respects as of the Closing Date; and 

d. No Default. There shall have occurred and be continuing no Seller Event of Default (as defined in
Section 18 hereof). 
 12.2. Conditions Precedent to Seller’s Obligations. Unless all the following conditions
are timely satisfied (or waived by Seller in its sole discretion), as evidenced by delivery of written notice thereof to Purchaser, then a condition precedent to Seller obligations under this Agreement shall have failed: 

a. Delivery of Funds. Prior to the Closing Date, Purchaser shall have delivered the balance of the Purchase Price
to the Title Company plus the costs, expenses and prorations (if any) required to be paid by Purchaser hereunder; 

  
 14 

 b. Purchaser’s Delivery of Closing Documents. Each of the
documents required to be delivered by Purchaser pursuant to Section 11.2 shall have been timely delivered as provided therein; and 
 c. Representations and Warranties and Covenants of Purchaser. Purchaser shall have performed the covenants and agreements to be performed by Purchaser hereunder by the time and in the manner
required by the terms of this Agreement, and Purchaser’s representations and warranties shall be true and correct in all material respects as of the Closing Date. 
 12.3. Failure of Conditions Precedent. 
 a. Failure by
Seller. If any condition precedent set forth at Section 12.1 is not satisfied by Seller (or otherwise waived by Purchaser) on or before the Closing Date, Purchaser may, at its option: (i) extend the Closing Date to allow Seller (at
Sellers’ option) a sufficient time within which to cure or satisfy any such condition, (ii) waive such condition and proceed to Closing, (iii) upon ten (10) business days’ notice to Seller, proceed pursuant to
Section 18 hereof. 
 b. Failure by Purchaser. If any condition precedent set forth at
Section 12.2 is not satisfied by Purchaser (or otherwise waived by Seller) on or before the Closing Date, Seller may, at its option: (i) extend the date for Closing to allow Purchaser (at Purchaser’s option) a sufficient time within
which to cure or satisfy any such condition (ii) waive such condition and proceed to Closing, (iii) upon ten (10) business days’ notice to Purchaser, terminate this Agreement, whereupon the Earnest Money Deposit shall be paid to
Seller, and neither party shall have any further obligation or liability hereunder except for those obligations which expressly survive the termination of this Agreement; or (iv) if the failure of the condition constitutes an Event of Default
by Purchaser hereunder, proceed pursuant to Section 18. 
 13. Seller’s Covenants Regarding Operation of the
Property Through the Closing Date. From and after the Effective Date and through the Closing Date, Seller shall: 
 a. Maintain (to the extent Seller is required to do so under the Lease), or use commercially reasonable efforts pursuant to the Lease to cause Tenant to maintain, all existing insurance policies affecting
the Property in full force and effect; 
 b. Maintain (to the extent Seller is required to do so under the Lease)
or cause Tenant to maintain the Property in such condition so that the Property shall be in substantially the same condition on the Closing Date as on the Effective Date, reasonable wear and tear and the occurrence of any damage or destruction to
the Property by casualty or other causes or events beyond the control of Seller excepted; 
 c. Not extend,
renew, modify or replace the Contracts (if any) or enter into any new contract regarding the Property without the prior written consent of Purchase; provided that any new contract, by its terms, is terminable on or before the Closing Date;

  
 15 

 d. Not, without the prior written consent of Purchaser, place any additional
liens, encumbrances, covenants, conditions, easements, or rights of way on the Property; 
 e. Not modify,
extend, terminate or otherwise change any terms, covenants or conditions of the Lease or enter into or approve any new leases, subleases, licenses or other occupancy agreements affecting the Property without the prior written consent of Purchaser;

 f. Promptly notify Purchaser of any material change in any condition of the Property of which Seller is aware.

 Seller shall request Purchaser’s written consent before taking any action contrary to the agreements set forth in this
Section 13 (a “Contrary Action”); provided that should Purchaser fail to either give or expressly refuse such written consent within five (5) business days of receiving the written request therefor from Seller, such consent shall
conclusively be deemed to have been given. Purchaser’s consent to any such Contrary Action may be withheld only upon reasonable grounds until the Contingency Date; thereafter, Purchaser may withhold such consent in its sole discretion.

 14. Eminent Domain. 
 a. Commencement of Action. In the event that at any time prior to the Closing, any notice of or proceeding shall be commenced or consummated for the taking of all or any part of the Property for
public or quasi-public use pursuant to the power of eminent domain or otherwise, Seller shall promptly give written notice thereof to Purchaser. 
 b. Purchaser’s Option to Cancel. The commencement or completion of any such proceeding shall have no effect on this Agreement unless Purchaser, by reason thereof, elects at its option, within
ten (10) business days after receipt by it of Seller’s notice of such taking, to cancel this Agreement by giving written notice thereof to Seller to such effect, and upon the giving of such notice, the Earnest Money Deposit with interest
thereon shall be refunded to Purchaser, and thereupon this Agreement shall become null and void and of lo further force or effect, with neither party having any further rights or liabilities hereunder, except or those obligations which expressly
survive the termination of this Agreement. If applicable, the Closing Date shall be extended for up to ten (10) business days in order to afford Purchaser the full ten (10) business day period in which to elect whether to proceed to
Closing or terminate this Agreement. 
 c. Purchaser’s Right to Purchase. If Purchaser shall elect to
proceed with the performance of this Agreement, notwithstanding the commencement of any such proceedings described herein, or the completion of any such taking, then Seller shall assign any and all awards and other compensation for any such taking
to Purchaser, and Seller shall convey all or such portion of the Property, if any, as shall be left after such taking in accordance with the terms of this Agreement; whereupon Purchaser shall not then be able; to seek any other damages or
compensation from Seller. 

  
 16 

 15. Risk of Loss or Damage. The risk of loss or damage to the Property by fire or
otherwise, is assumed by Seller until Closing of this transaction. In the event of such loss or damage requiring One Hundred Thousand and 00/100 Dollars ($100,000.00) or more to repair such damage, as determined by an adjuster reasonably acceptable
to Purchaser and Seller (the “Repair Estimate”), the Purchaser may, at Purchaser’s option (elected by written notice to Seller within ten (10) business days following Purchaser’s receipt of the Repair Estimate),
(a) terminate this Agreement and secure an immediate refund of the Earnest Money Deposit and interest thereon, or (b) purchase the Property as is in which event all insurance proceeds and any deductible applicable thereto shall be paid to
Purchaser; provided, however, that: (i) any such assignment of casualty insurance proceeds shall not exceed the Repair Estimate; (ii) in no event shall Seller be obligated to pay any amount by which the Repair Estimate exceeds the
insurance proceeds and the deductible; and (iii) Purchaser shall not then be able to seek any other damages or compensation from Seller. In the event of any casualty other than as described above, the parties shall proceed to Closing in
accordance with subsection (b) of this Section 15. 
 16. Notices. Any notice, request, approval, demand,
instruction or other communication to be given to either party hereunder, except those required to be delivered at Closing, shall be in writing, and shall, subject to Section 19(e), be deemed to have been given and received upon:
(a) receipt, if hand delivered, (b) transmission, if delivered by facsimile transmission (as evidenced by electronic confirmation of transmission generated by the sender’s facsimile machine), (c) the next business day, if
delivered by express delivery service or overnight courier service, or (d) the third business day following the day of deposit of such notice in registered or certified mail, return receipt requested. Notices shall be provided to the addresses
(or facsimile numbers, as applicable) specified below: 
  

	         If to Seller 
	Cranwoods-WST, Ltd. 

	 	1468 West Ninth Street, Suite 135 

	 	Cleveland, OH 44113 

	 	Attn: Chief Investment Officer 

	 	Facsimile: (216) 566-7579 

  

	         With a copy to: 
	Thorp Reed & Armstrong, LLP One 

	 	Oxford Centre, 15th Floor 

	 	301 Grant Street 

	 	Pittsburgh, PA 15219 

	 	Attn: Jeffrey J. Conn, Esq. 

	 	Facsimile: (412) 394-2525 

  

	         If to Purchaser: 
	Westgate North LLC 

	 	521 Fifth Avenue, 24th Floor 

	 	New York, NY 10017 

	 	Attn: Moishie M. Klein, Esq. 

	 	Facsimile: (732) 942-9998 

 The parties may change their respective
addresses and/or telefax/telecopy numbers for the receipt of notice hereunder by giving notice thereof to the other party in accordance herewith. 

  
 17 

 17. Brokers’ Commissions. Except with respect to Jones Lang LaSalle,
representing Seller (“Seller’s Broker”), and MSR Realty Corp. representing Purchaser (the “MSR Broker”), Seller and Purchaser hereby represent and warrant to the other party that, in connection with this transaction, no
other third-party broker or finder has been engaged or consulted by it or through such party’s actions (or claiming through such party) is entitled to compensation as a consequence of this transaction. At Closing, Seller shall remit a
commission due and payable to Seller’s Broker, and to MSR Broker, pursuant to separate agreements between the parties. Seller and Purchaser hereby agree to indemnify, defend and hold the other party harmless against any and all claims of
brokers, finders or the like, and against the claims of all third parties, other than the Seller’s Broker and MSR Broker, respectively, claiming any right to commission or compensation by or through acts of the indemnifying party or its
partners, agents or affiliates in connection with this Agreement. The indemnifying party’s indemnity obligations shall include all damages, losses, costs, liabilities and expenses, including reasonable attorneys’ fees and litigation costs,
which may be incurred by the other party. The provisions of this Section 17 shall survive the Closing. 
 18. Defaults
and Remedies. 
 a. Default by Seller. Except where due to the occurrence of a Section 19.n.
Force Majeure event or an Event of Default by Purchaser, in the event that: (i) Seller’s fails to satisfy any condition precedent set forth at Section 12.1(a), 12.1 (b) or 12.1(c) hereof, and Seller shall not have cured said
failure within ten (10) business days after written notice thereof from Purchaser, then such failure shall constitute an “Event of Default” by Seller hereunder. In the Event of Default by Seller, as defined pursuant to this
Section 18, Purchaser shall be entitled to either: (a) terminate this Agreement by written notice to Seller within ten (10) days of the occurrence of the Event of Default, in which event Purchaser shall be entitled to receive an
immediate refund of the Earnest Money Deposit, together with reimbursement from Seller of all of Purchaser’s out-of-pocket costs and expenses, including without limitation reasonable legal fees and expenses, actually incurred in connection
with: (i) its due diligence investigations; (ii) the Survey (ii) the Title Commitment; (iv) Purchaser’s proposed financing of the acquisition of the Property; and (v) all other costs incurred by Purchaser in connection
with the negotiations or performance of this Agreement; or (b) pursue specific performance of this Agreement against Seller; provided, however, that Seller shall not be entitled to pursue such specific performance in the event that the subject
Event of Default arose out of Seller’s failure to deliver to Purchaser at Closing those items required pursuant to Sections 11.1(g), (h), (i), (j), (1), (n) and/or (o) hereof. 

b. Default by Purchaser. Except where due to the occurrence of a Section 19.n. Force Majeure event or an Event
of Default by Seller, the following shall constitute Events of Default by the Purchaser pursuant to this Agreement: (i) Purchaser shall fail to fully and timely perform any of Purchaser’s monetary obligations arising under this Agreement,
including without limitation the timely deposit of the Earnest Money Deposit, where such failure continues for five (5) business days after the date when due; (ii) Purchaser shall fail to fully and timely perform any of Purchaser’s
material, nonmonetary obligations arising under this Agreement, where such failure continues for ten (10) business days after Purchaser’s receipt of written notice from Seller of such default; or (iii) Purchaser otherwise fails to
complete the acquisition of the Property on the Closing Date. 

  
 18 

 In the Event of Default by Purchaser hereunder, the Earnest Money Deposit and any interest
thereon shall be paid to Seller as liquidated damages (and not as a penalty) as Seller’s sole and exclusive remedy for such default, it being mutually acknowledged and agreed that the amount of Seller’s damages for Purchaser’s default
would he difficult or impossible to ascertain in advance and that the amount of the Earnest Money Deposit constitutes a reasonable approximation thereof. Seller hereby specifically waives any and all rights which it may have to damages or specific
performance as a result of any Event of Default by Purchaser under this Agreement. 
 19. Miscellaneous. 

a. Binding Effect. This Agreement is binding upon and inures to the benefit of the parties hereto and their
respective heirs, legal representatives, executors, administrators, successors and assigns. 
 b.
Assignment. Purchaser may assign this Agreement without Seller’s prior consent, provided that Purchaser shall bear sole responsibility for any and all state, county and municipal documentary and transfer taxes and related surtax related
in any manner to such assignment. If the assignment by Purchaser occurs after the deposit of the Earnest Money Deposit, Purchaser shall be released from any further liability hereunder. In no event shall any assignment of this Agreement prior to the
deposit of the Earnest Money Deposit release the Purchaser from its obligations hereunder and, upon any breach or default by any assignee pursuant to this Agreement prior to the deposit of the Earnest Money Deposit, the Seller may enforce its
rights, directly against the assignor without making the assignee a party to such action or proceeding. 
 c.
Confidentiality. The parties each agree that they will keep confidential any information designated as such by the other or not otherwise publicly available which is derived from access, investigation or information furnished by either party
in connection with this Agreement, including the negotiations conducted in connection herewith, and, if the transactions contemplated hereby are not consummated, will promptly return to the other all such information and will not thereafter use such
information; provided that such confidentiality obligations shall not preclude a party from delivering such information to its potential investors or attorneys, lenders and consultants hired in connection with this transaction or as otherwise
required by law. 
 d. Construction. The terms and provisions of this Agreement represent the results of
negotiations between Seller and Purchaser, each of which are financially sophisticated parties and each of which has been represented or been given the opportunity to be represented by counsel of its/his/her own choosing, and neither of which has
acted under any duress or compulsion, whether legal, economic or otherwise. Consequently, the terms and provisions of this Agreement shall be interpreted and construed in accordance with their usual and customary meanings, and Seller and Purchaser
each hereby waive the application of any rule of law which would otherwise be 

  
 19 

 
applicable in connection with the interpretation and construction of this Agreement that ambiguous or conflicting terms or provisions contained in this Agreement shall be interpreted or construed
against the party whose attorney prepared the executed Agreement or any earlier draft of the same. The parties agree that, regardless of which party provided the initial form of this Agreement, drafted or modified one or more provisions hereof, or
compiled, printed or copied this Agreement, this Agreement shall be construed solely as an offer to purchase from Purchaser, executed by Purchaser and provided to Seller for acceptance on the terms set forth herein, which acceptance and the
existence of a binding agreement between Purchaser and Seller shall be evidenced by the execution hereof by Seller. 
 e. Exhibits/Time Periods. Any reference herein to any exhibits, addenda or attachments refers to the applicable exhibit, addendum or attachment that is attached to this Agreement, and all such
exhibits, addenda or attachments shall constitute a part of this Agreement and are expressly made a part hereof. If any date, time period or deadline hereunder falls on a weekend or a state or federal holiday, then such date shall be extended to the
next occurring business day. 
 f. Agreement Separable. If any provision hereof is for any reason
unenforceable or inapplicable, the other provisions hereof will remain in fall force and effect in the same manner as if such unenforceable or inapplicable provision had never been contained herein. 

g. Counterparts. This Agreement may be executed in any number of counterparts, each of which will, for all
purpc6es, be deemed to be an original, and all of which are identical. 
 h. Governing Law. This Agreement
shall be governed by and construed in accordance with the laws of the Commonwealth of Pennsylvania. 
 i.
Survival. All representations, covenants and agreements of the parties which, by the express context of this Agreement, are to be performed after or are to survive the termination of this Agreement or the Closing, shall, as the case may be,
survive the Closing or the termination of this Agreement for the period expressly provided for in this Agreement. 
 j. Entire Agreement. This Agreement constitutes the entire agreement between Seller and Purchaser, and there are no other covenants, agreements, promises, terms and provisions, conditions,
undertakings or understandings; either oral or written, between them concerning the Property other than those herein set forth. No subsequent alteration, amendment, change, deletion or addition to this Agreement shall be binding won Seller or
Purchaser unless in writing and signed by both Seller and Purchaser. 
 k. Time is of the Essence. Time is
of the essence in the performance of the parties’ respective obligations under this Agreement. 
 l.
Attorneys’ Fees. In any action or litigation between Purchaser and Seller as a result of failure to perform or default under this Agreement, the prevailing party shall 

  
 20 

 
be entitled to recover such reasonable attorneys’ fees and court costs as may be awarded by the court. As used herein the term “prevailing party” shall be the party to such
litigation which receives whether by settlement or judgment substantially the relief prayed for in such litigation. This provision shall survive Closing or any termination of this Agreement. 

m. 1031 Exchange. Either party may consummate the purchase or sale of the Property as part of a so-called like kind
exchange (the “Exchange”) pursuant to §1031 of the Internal Revenue Code of 1986, as amended ( the “Code”), provided that: (i) the non-exchanging party shall be provided no less than five (5) days’ prior
written notice of such Exchange, and the Closing shall not be delayed or affected by reason of the Exchange, nor shall the consummation or accomplishment of the exchange be a condition precedent or condition subsequent to either party’s
obligations under this Agreement; (ii) the exchanging party shall effect the Exchange through an assignment of this Agreement, or its rights under this Agreement, to a qualified intermediary; and (iii) the non-exchanging party shall not be
required to take an assignment of the purchase agreement for the relinquished property or be required to acquire or hold title to any real property For purposes of consummating the Exchange. The non-exchanging party shall not by this agreement or
acquiescence to the Exchange (1) have its rights under this Agreement affected or diminished in any manner or (2) be responsible for compliance with or be deemed to have warranted to the exchanging party that the Exchange in fact complies
with §1031 of the Code. The cooperating party shall not be required to incur any liability with respect to any exchanged property, nor incur any other monetary liabilities or costs or expenses of any type, when participating in the exchange.

 n. Force Majeure. Purchaser and Seller shall be excused for the period of any delay in performance of
any obligations hereunder by reason of labor disputes, civil disturbance, war, war-like operations, invasions, rebellion, hostilities, military or usurped power, sabotage, governmental regulations or controls, fires or other casualty, inclement or
adverse weather of unusual amount or duration for the subject season, or acts of God In order to be entitled to an excuse for any delay or failure to perform under this Agreement pursuant to this Section, the party claiming such excuse shall
promptly give written notice to the other party hereto of any event or occurrence which the notifying party asserts to be within the contemplation of this Section 6.18 and shall exercise all reasonable efforts to remove the cause of such delay.

 o. Allocation of Liability. It is expressly understood and agreed that Seller shall be liable to third
parties for any and all obligations, claims, losses, damages, liabilities, and expenses arising out of events, contractual obligations, acts, or omissions of Seller that occurred in connection with the ownership or operation of the Property prior to
the Closing, and Purchaser shall be liable to third parties for any and all obligations, claims, losses, damages, liabilities and expenses arising out of events, contractual obligations, acts, or omissions of Purchaser that occur in connection with
the ownership or operation of the Property after the Closing. 
 p. No Personal Liability. Seller and
Purchaser agree that there shall be absolutely no personal liability on the part of any shareholder, director, officer, employee 

  
 21 

 
or agent of any Sellers and Purchaser or their Affiliates with respect to any of the terms, covenants and conditions of this Agreement. For purposes of this Section, “Affiliate” means
any entity or person, as applicable, controlling, controlled by or under common control with the person or entity in question. 
 q. Nonrecordation. The parties hereto agree that neither this Agreement nor any notice or memorandum thereof shall be recorded in any public records. Violation of this provision shall constitute an
Event of Default hereunder. 
 r. Offer and Acceptance. This Agreement, as signed and submitted by either
party, shall constitute an offer, which shall automatically expire on August 19, 2011 at 5:00 p.m. EST unless accepted fully executed and delivered by both parties prior thereto. 

s. Prior Agreement. The parties agree and acknowledge that, as of the Effective Date, this Agreement shall
supersede the terms of that certain Purchase Agreement entered into by the parties and dated as of August 10, 2011 (the “Prior Agreement”); which Prior Agreement shall be null, void and of no further force or effect as of the
Effective Date hereof. 
 {Remainder of Page Left Intentionally Blank; Signatures Follow on Next Page} 

  
 22 

 IN WITNESS WHEREOF, the parties hereto have executed this Agreement effective as of
the date first above written. 
  

			
	Purchaser:
	
	 WEC-CRANBERRY LLC, a Delaware
 limited liability company

		
	By:	 	 /s/ Moishie M. Klein

	Name:	 	Moishie M. Klein
	Its:	 	Authorized Signatory
		
	Seller:	 	
	
	 CRANWOODS-WST, LTD, a
 Pennsylvania limited partnership

	
	 By: TFG Investments IV, LLC, a
 Pennsylvania limited partnership, its sole
 general partner

	
	 By: JTMK-WST, Ltd., an Ohio limited
 partnership, its sole member

	
	 By: TFG Development, LLC, an Ohio
 limited liability company, its sole general
 partner

		
	By:	 	 /s/ Martin L. Herman

	Name:	 	 Martin L. Herman

	Its: 	 	Manager

  
 23Westinghouse Lease

 Exhibit 10.3 
 LEASE AGREEMENT 
 THIS LEASE AGREEMENT (this
“Lease”) is made and entered into as of the date of the parties’ mutual execution hereof (the “Effective Date”), by and between CRANWOODS-WST, LTD., a Pennsylvania limited partnership having an address of 1468
West Ninth Street, Suite 135, Cleveland, OH 44113 (the “Landlord”), and WESTINGHOUSE ELECTRIC COMPANY LLC, a Delaware limited liability company having an address of 1000 Westinghouse Drive, Cranberry Township, PA 16066 (the
“Tenant”). 
 1. SUMMARY OF BASIC LEASE TERMS. 

 

					
	Premises	  	-	  	All that certain land located in Cranberry
		  		  	Township, Butler County, Pennsylvania,
		  		  	being designated as Lot No. 3 in the
		  		  	Revision No. 2 to Cranberry Woods Plan
		  		  	No. 1, and all appurtenances thereto,
		  		  	together with approximately 118,031 square
		  		  	feet of rentable area to be constructed
		  		  	thereupon, as more particularly designated at
		  		  	Section 2 hereof (subject to contraction in
		  		  	accordance with Section 2.5 hereof)
			
	Initial Term	  	-	  	Fifteen (15) Lease Years from the
		  		  	Commencement Date (as such terms are
		  		  	defined at Sections 3.1 and 3.2(a),
		  		  	respectively)
			
	Options to Extend	  	-	  	Two (2) Extension Terms of Five (5) years
		  		  	each, together with One (1) Extension Term
		  		  	of Four(4) years, Eleven (11) months
			
	Option to Terminate	  	-	  	Effective as of the last day of the tenth
		  		  	(10th) Lease Year, exercisable in accordance
		  		  	with the conditions set forth at Section 3.4
			
	Base Rent	  	-	  	$25.04 per rentable square foot through the
		  		  	last day of the fifth (5th) Lease Year;
			
		  		  	$26.04 per rentable square foot through the
		  		  	last day of the tenth (10th) Lease Year; and
			
		  		  	$27.04 per rentable square foot through the
		  		  	last day of the Initial Term
			
		  		  	(subject to increase during any Extension
		  		  	Terms in accordance with Section 5.2)

  
 1 

					
	Additional Rent	  	-	  	Includes Tenant’s obligation to pay all
		  		  	Taxes and other Additional Rent in
		  		  	accordance with Sections 5.3 and 5.4,
		  		  	respectively.
			
	Security Deposit	  	-	  	None
			
	Addresses for Notices	  	-	  	As to Landlord:
		  		  	Cranwoods-WST, Ltd.
		  		  	1468 West Ninth Street, Suite 135
		  		  	Cleveland, OH 44113
		  		  	Attn: Chief Investment Officer
		  		  	Fax: (216) 566-7579
			
		  		  	With copy to:
		  		  	Thorp Reed & Armstrong, LLP
		  		  	One Oxford Centre, 15th Floor
		  		  	301 Grant Street
		  		  	Pittsburgh, PA 15219
		  		  	Attn: Jeffrey J. Conn, Esq.
		  		  	Fax: (412) 394-2555
			
		  		  	As to Tenant:
			
		  		  	Westinghouse Electric Company, LLC
		  		  	1000 Westinghouse Drive
		  		  	Suite 127
		  		  	Cranberry Township 16066
		  		  	Attn: Russell L. Bussard
		  		  	Fax: (724) 940-8502
			
		  		  	With copy to:
			
		  		  	Westinghouse Electric Company, LLC
		  		  	1000 Westinghouse Drive
		  		  	Suite 138
		  		  	Cranberry Township 16066
		  		  	Attn: Michele M. Gutman, Esq.
		  		  	Fax: (724) 940-8505

  
 2 

					
	 	  	 	  	And with copy to:
			
		  		  	Reed Smith LLP
		  		  	Reed Smith Center
		  		  	225 Fifth Avenue
		  		  	Pittsburgh, PA 15222
		  		  	Attn: Ronald G. Hartman, Esq.
		  		  	Fax: (412) 288-3063

  

	*	Note: If there is any difference between this Summary and the Lease, the Lease shall control. 

 2. DEMISE AND PREMISES. 
 2.1 ACCEPTANCE. Subject to the terms,
covenants and conditions of this Lease, Landlord leases to Tenant, and Tenant leases from Landlord all that certain land located in Cranberry Township, Butler County, Pennsylvania, being designated as Lot No. 3 in the Revision No. 2 to
Cranberry Woods Plan No. 1 (the “Plan”), as recorded in the Office of the Recorder of Deeds of Butler County in Plan Book Volume 301, Pages 8 and 9 and containing approximately 24.741 acres (said Lot No. 3, as is more
particularly described at Exhibit “A” attached hereto and made a part hereof, shall hereinafter be designated as the “Land”), together with all buildings, structures and improvements to be constructed thereupon by Landlord
in accordance with the terms and conditions set forth in this Lease (collectively, the “Improvements”), which Improvements shall be performed in accordance with the terms and conditions of this Lease, including without limitation
those set forth at Exhibit “B” attached hereto and made a part hereof (the “Work Letter”) and shall include, without limitation, that certain approximately 122,100 gross square foot, approximately 118,031 rentable square
foot building (the “Building”) and other Improvements to be constructed upon the Land by Landlord in accordance with the plans and specifications prepared by LLI/IKM and attached hereto as Exhibit “B-1” and made a part
hereof (the “Improvements Plans and Specifications”), and the tenant improvements to be constructed by Landlord within the Building (the “Tenant Improvements”) in accordance with the plans and specifications
prepared by LLI/IKM and attached hereto as Exhibit “B-2” and made a part hereof (“Tenant Improvements Plans and Specifications”). The Improvements, including the Building and the Tenant Improvements and the Land on which
they are or shall be situated, together with all easements, rights-of-way and appurtenances thereto, are hereinafter designated as the “Premises”. Tenant shall lease and occupy the Premises under and subject to all applicable laws,
ordinances, regulations, covenants, conditions, restrictions and easements, and further subject to that certain Declaration of Protective Covenants for Cranberry Woods, made as of October 28, 1998, by Mine Safety Appliances Company, and
recorded in the Office of the Recorder of Deeds of Butler County in Record Book Volume 2928, Page 28 (as amended to date, the “Declaration”), a copy of which Declaration has been provided to Tenant as of the Effective Date.

  
 3 

 2.2 ASSIGNMENT OF OPTION AGREEMENT. 

(a) Tenant represents to Landlord that, as of the Effective Date, Tenant has the right and option to acquire legal title to the Premises
pursuant to that certain Option Agreement and Agreement of Sale, dated as of July 26, 2007, by and between Mine Safety Appliances Company (“MSA”), as seller, and Tenant, as buyer (as the same has heretofore or hereafter been amended,
the “Option Agreement”); which Option Agreement shall, in accordance with the terms hereof, be assigned by Tenant to Landlord; provided, however, that in the event that the Option Agreement is not so assigned by Tenant to Landlord
on or before September 30, 2009, either party shall have the right and option, upon ten (10) days’ written notice to the other, to terminate this Lease, whereupon the parties shall have no further obligations hereunder. Subject to the
terms and conditions set forth at Section 2.2(b) below, in the event that Tenant fails or refuses to assign the Option Agreement to Landlord in accordance with the terms hereof despite Landlord’s written request that such assignment be
effectuated, then: (i) upon any termination of this Lease in accordance with this Section 2.2(a), Tenant shall be obligated to reimburse Landlord for all of Landlord’s reasonable out-of-pocket costs and expenses actually incurred in
connection with its preparation and negotiation of this Lease, including without limitation all reasonable attorney and other professional fees; or (ii) Landlord shall otherwise be entitled to institute, at Tenant’s sole cost and expense,
an action for specific performance to compel Tenant’s assignment of the Option Agreement. Landlord agrees that, as of the Effective Date, Tenant is attempting to amend the Option Agreement to, inter alia, accelerate the Closing Date to
five (5) days (or such other number of days as agreeable to MSA and less than 75) following the Buyer’s exercise of the Option (as such capitalized terms are defined in the Option Agreement) and Landlord hereby agrees to such accelerated
Closing Date. 
 (b) The obligation of Tenant to assign the Option Agreement to Landlord is contingent upon Landlord, on or
prior to such assignment, (i) having received from Landlord evidence of Landlord’s ability to acquire the Land and to construct the Improvements and Tenant Improvements, which evidence shall be reasonably acceptable to Tenant; and
(ii) having entered into a construction contract with Turner Construction Company for the construction of the Improvements and the Tenant Improvements. 
 (c) If for any reason the Option Agreement is assigned to Landlord prior to the satisfaction of both the conditions set forth in Section 2.2(b) above, Landlord agrees that it will not exercise the
option to purchase the Land under the Option Agreement until both said conditions are satisfied and Landlord is unconditionally committed to proceeding to promptly close on the acquisition of the Land and promptly thereafter starting construction of
the Improvements and thereafter diligently prosecuting completion thereof and of the Tenant Improvements in accordance with the terms of this Lease. 
 (d) Subject to the terms and conditions set forth at Section 2.2(a) above, in the event that closing on the acquisition by Landlord of the Land, closing on such proposed acquisition and construction
loan by Landlord with its lender and/or commencement of construction of the Improvements by Landlord has not occurred by the date that is the earlier to occur of: (i) seventy five (75) days following the date on which the Option Agreement
is 

  
 4 

 
assigned to Landlord pursuant to Section 2.2(a) above; or (ii) such earlier date as may be agreed to for Closing pursuant to the Option Agreement (as it may be amended), then in any
such event, Tenant may, upon fifteen (15) days’ written notice to Landlord, terminate this Lease and all rights and obligations of the parties hereunder, except that Landlord shall: (i) to the extent that the closing on the
acquisition of the Land has not yet occurred, reassign the Option Agreement to Tenant for no consideration; and (ii) to the extent that the closing on the acquisition of the Land has occurred, Landlord shall convey the Land to Tenant for the
purchase price paid by Landlord. In the event that such reassignment of the Option Agreement and/or conveyance of the Land is occasioned by Landlord’s default under this Lease or under the Option Agreement, or otherwise occasioned by any other
delay or action of Landlord or its lenders, contractors, partners or investors, Landlord shall pay all real estate transfer taxes associated with such reassignment and/or conveyance. In the event that such reassignment of the Option Agreement and/or
conveyance of the Land is occasioned by Tenant’s default under this Lease, Tenant shall pay all real estate transfer taxes associated with such reassignment and/or conveyance. In the event that such reassignment of the Option Agreement and/or
conveyance of the Land is occasioned other than as expressly contemplated pursuant to this Section 2.2(d), including by reason of MSA’s default under the Option Agreement, Landlord and Tenant shall share equally all real estate transfer
taxes associated with such reassignment and/or conveyance. 
 (e) Subject to the terms of Section 2.2(b) above, in the
event that the Option Agreement is not assigned by Tenant to Landlord on or before September 30, 2009, or in the event that closing on the acquisition of the Land pursuant to the Option Agreement does not occur on or before September 30,
2009 and such failure is not attributable to a default by Landlord thereunder, or attributable to any other delay or action of Landlord or its lenders, contractors, partners or investors, then each of the Target Completion Dates (as defined at
Section 3.2(c) hereof) shall be postponed, by one (1) day, for each day that such assignment and/or acquisition, as applicable, is delayed beyond September 30, 2009. 

2.3 OWNERSHIP OF IMPROVEMENTS. Notwithstanding anything to the contrary set forth in this Lease, title to all Improvements, to the
extent not otherwise owned by Landlord, shall automatically transfer and revert to Landlord, without the need for further documentation of any kind, upon the expiration or earlier termination of this Lease. Except as may be otherwise expressly
provided in this Lease, and subject only to Tenant’s leasehold interest during the Term as expressly granted hereunder, Tenant shall have no right, title or interest in or to, nor any right to remove, the Improvements at any time prior to,
during or following the expiration of the Term without Landlord’s prior written consent, which consent may be withheld in Landlord’s sole discretion; provided, Tenant may, from time to time during the term of the Lease (including Extension
Terms) at its cost and expense, remove and/or replace any of the Tenant Improvements and the HVAC and other equipment servicing the Premises (and which are to be maintained by Tenant under this Lease); all such removals and replacements shall be
performed in accordance with the requirements for Alterations hereinafter set forth. 
 2.4 ADJUSTMENT. The parties
acknowledge and agree that, as of the Lease Date, the applicable terms and calculations set forth in this Lease have been determined based upon the Building being comprised of 118,031 rentable square feet. Not less than thirty (30) days prior
to 

  
 5 

 
Substantial Completion of the Building, including the Tenant Improvements, Landlord shall deliver to Tenant a certificate as to the number of rentable square feet therein based upon an opinion of
LLI/IKM and measured in accordance with applicable BOMA standards, and, to the extent applicable, the rentable area of the Premises described herein and the calculation of Rent (as hereinafter defined), shall be adjusted accordingly. In no event
shall the rentable square feet of the Building be less than 115,670 rentable square feet nor more than 120,392 rentable square feet. 
 2.5 OPTION TO CONTRACT. Tenant shall have the right to surrender to Landlord a portion of the Premises, and terminate this Lease solely as it relates to such portion, effective as of the last day
of the tenth (10th) Lease Year, as hereinafter
defined (the “Contraction Effective Date”), subject to the following terms and conditions: 
 (a) Tenant shall
give written notice to Landlord of its election to so contract, which notice shall: (i) be given no later than the first day of the calendar month that is eighteen (18) months preceding the Contraction Effective Date; and
(ii) indicate the specific portion(s) of the Premises proposed to be surrendered; provided, however, that in no event shall Tenant be entitled to exercise its option to contract in accordance with this Section 2.5 as to less than any
entire floor within the Building. 
 (b) Upon Tenant’s exercise of its contraction option hereunder, a contraction fee (the
“Contraction Fee”) shall automatically become due from Tenant to Landlord in an amount equal to the then-unamortized principal balance of each of (i) the Tenant Improvement Allowance (based on a Tenant Improvement Allowance of
$50/square foot, as set forth on Exhibit “D” attached hereto and incorporated herein); and (ii) the brokerage commissions paid by Landlord in connection with this Lease (based on a brokerage commission of $11.46/square foot, as set
forth on Exhibit “D” attached hereto and incorporated herein); both of which items set forth at subsections 2.5(b)(i) and (ii) hereof shall be amortized on a mortgage amortization basis assuming an amortization period of one hundred
eighty (180) months beginning as of the Commencement Date, and an imputed interest rate of eight percent (8%) per annum (an amortization schedule of which, based on 118,031 square feet, is appended to this Lease as Exhibit “D”);
the schedule attached hereto as Exhibit “D” is based on a total rentable square footage within the Building of 118,031 rentable square feet and shall be adjusted if the rentable square footage of the Building is adjusted pursuant to the
terms of Section 2.4, above and the determination of the amount of the Contraction Fee payable on the Contraction Effective Date shall be based upon the proportion that the rentable square footage of the surrendered portion of the Premises
bears to the rentable square footage of the Premises in its entirety. Tenant shall pay to Landlord the Contraction Fee on or before the Contraction Effective Date. In the event that the Contraction Fee is not timely paid by Tenant, Landlord shall
provide Tenant with not less than ten (10) days written notice of such failure to pay and if Tenant does not thereafter pay the same within such ten (10) day period, Tenant’s right to contract the Premises in accordance with this
Section 2.5 shall be deemed void, invalid and of no force or effect, and this Lease shall continue in full force and effect without regard to this Section 2.5. 

  
 6 

 (c) All portions of the Premises surrendered to Landlord in accordance with this
Section 2.5 shall be tendered to Landlord. by Tenant in a condition consistent with the requirements set forth at Section 16 of this Lease. 
 (d) Landlord and Tenant shall execute an amendment to this Lease, which amendment shall, as of the Contraction Effective Date: (i) adjust Tenant’s Base Rent; (ii) adjust the definition and
depiction of the Premises; (iii) establish the terms and conditions pursuant to which Tenant shall pay its pro-rata share of agreed upon costs of operating the Property (“Property Costs”) and Taxes (as hereinafter defined at
Section 5.3), and account for the creation of common areas upon the Premises and/or within the Building as may be necessary; and (iv) establish all other requisite revisions hereto necessitated pursuant to Tenant’s contraction of the
Premises in accordance with this Section 2.5. 
 3. TERM. 

3.1 INITIAL TERM. The initial term of this Lease (the “Initial Term”) will commence on the
Commencement Date (as hereinafter defined at Section 3.2) and continue until the last day of the fifteenth
(15th) Lease Year thereafter, unless sooner
terminated pursuant to any of the provisions, terms or covenants of this Lease. The term “Lease Year” shall mean the twelve (12)-month period beginning on the Commencement Date and each successive twelve (12)-month period thereafter
within the Term, provided that, if the Commencement Date shall be other than the first (1st) day of a calendar month, then the first (0) Lease Year shall extend from the Commencement Date through the end of the twelfth (12th) complete calendar month after the Commencement Date. 

3.2 COMMENCEMENT DATE. 
 (a) The “Commencement Date” of this Lease shall be established as of the later to occur of (a) the date that is ninety (90) days following the date of Substantial Completion of
all of the Improvements, including the Building and Tenant Improvements; or (b) January 1, 2011. Upon the determination of the date of Substantial Completion and the Commencement Date, at either party’s request, Landlord and Tenant
shall sign an agreement setting forth the Commencement Date and the expiration date of the Initial Term; provided, however, that the failure of the parties to do so shall not affect the determination of such dates, nor Landlord’s or
Tenant’s respective rights and obligations hereunder from and after the Commencement Date. 
 (b) Landlord shall construct
and complete all the Improvements, including the Building and all the Tenant Improvements, in accordance with the Improvements Plans and Specifications and the Tenant Improvements Plans and Specifications and the terms and provisions of the Work
Letter. 
 (c) Landlord shall use commercially reasonable efforts to Substantially Complete the Improvements, including the
Building and the Tenant Improvements, as follows: the Building, certain of the parking areas (subject to the terms and provisions of Section 43 below) and all Tenant Improvements on the First Floor of the Building shall be Substantially

  
 7 

 
Completed on or before October 1, 2010; all Tenant Improvements on the Second Floor of the Building, together with certain of the parking areas (subject to the terms and provisions of
Section 43 below) shall be Substantially Completed on or before October 15, 2010; and all Tenant Improvements on the Third Floor of the Building, together with certain of the parking areas (subject to the terms and provisions of
Section 43 below) shall be Substantially Completed on or before November 1, 2010. If Landlord is unable to Substantially Complete all of the Building and other Improvements, including all Tenant Improvement Work on the respective floors in
accordance with the above Schedule (each a “Target Completion Date”), and such delay is not due to any act, omission of Tenant or its agents, representatives, contractors or employees, or to a Tenant Change Order as defined in
Section 2.2 of the Work Letter (in which event each of the Target Completion Dates shall be adjusted as set forth therein), or to any Force Majeure Event (as hereinafter defined at Section 42), or, subject to the terms of
Section 2.2(b) above, to the failure of Tenant to assign the Option Agreement to Landlord on or before September 30, 2009 as set forth at Section 2.2(e) above (in which event, subject to the limitations set forth at
Section 2.2(e) above, each of the Target Completion Dates shall be adjusted as set forth therein), or to the failure of Landlord to acquire the Land pursuant to the Option Agreement on or before September 30, 2009 as set forth at
Section 2.2(e) above (in which event, subject to the limitations set forth at Section 2.2(e) above, each of the Target Completion Dates shall be adjusted as set forth therein), Tenant shall: (i) accrue one (1) day of free Rent
for each of the first thirty (30) days beyond such Target Completion Date that such Substantial Completion is delayed by Landlord; (ii) accrue two (2) days of free Rent for each of the second successive thirty (30) days beyond
the applicable Target Completion Date(s) that such applicable Substantial Completion is delayed by Landlord; (iii) accrue three (3) days of free Rent for each day beyond the sixtieth (60th) day after the applicable Target Completion
Date that such applicable Substantial Completion(s) is delayed by Landlord. In the event that Substantial Completion of all the Improvements and all the Tenant Improvements is delayed by Landlord for more than ninety (90) days following the
November 1, 2010 Target Completion Date, Tenant shall have the right, upon thirty (30) days additional written notice to Landlord, and as its sole and exclusive remedies as a result of such failure by Landlord, to: (x) terminate this
Lease, whereupon neither party shall have any further liability under this Lease except that Landlord shall be liable to Tenant for the value of all free rent accrued to the date of termination of this Lease and Tenant shall have the right, at its
option, to acquire the Premises (the “Liquidated Damages Purchase Option”) pursuant to the terms set forth in Section 3.2(d) by notifying Landlord in writing that Tenant is exercising the Liquidated Damages Purchase Option; or
(y) perform any incomplete work to complete the Building, other Improvements and/or the Tenant Improvement(s), as applicable, on behalf of Landlord. In the event that Tenant elects to perform any such incomplete work pursuant to subsection
(y) of this Section 3.2(b), Tenant shall, as of the Commencement Date, be entitled to a credit against Rent in the amount of (A) all reasonable costs and expenses incurred by Tenant as a result of said work and (B) Tenant shall
be entitled to free Rent for each day after each applicable Target Completion Date until Substantial Completion of each applicable portion of the Building, Improvements and/or Tenant Improvements; provided that the parties shall, prior to
Tenant’s commencement of any such work, attempt to agree in writing upon a budget for any and all costs and expenses associated with any such incomplete Base Building Work and Tenant Improvement Work, but failure of the

  
 8 

 
parties to so agree shall not delay or prevent Tenant from exercising its remedies hereunder and Landlord shall reserve its rights to contest the reasonableness of any claim of Tenant for costs
incurred by Tenant to complete the Improvements and the Tenant Improvements. 
 (d) Liquidated Damages Purchase Option. If
Tenant exercises the Liquidated Damages Purchase Option, the following terms and provisions shall apply: 
 (i) The purchase
price for the Premises (“LDPO Purchase Price”) shall be equal (i) to the purchase price paid by Landlord under the Option Agreement to acquire title to the Land and (ii) all reasonable development costs incurred by
Landlord in connection with the Project including, but not limited to, all reasonable costs and expenses relating to architectural and engineering directly related to the Improvements, Tenant Improvements, inspections, insurance, appraisals,
professional fees and financing costs, but specifically excluding any costs and expenses and/or fees payable or paid to Landlord or any person or entity affiliated with the Landlord, and Tenant, at Tenant’s sole option, may elect to assume the
construction contracts for the Base Building Work and Tenant Improvement Work (collectively, the “Construction Contracts” and individually, a “Construction Contract”) and/or any other agreement relating to the
design or construction of the Improvements and Tenant Improvements; provided, if Tenant gives Landlord written notice to stop construction in connection with Tenant’s exercise of the Liquidated Damage Purchase Option and/or to terminate any
Construction Contract or any third party agreement, then such Construction Contract(s) and/or other third party agreements shall be terminated by Landlord at no expense to Tenant. 

(ii) If Tenant properly exercises the Liquidated Damage Purchase Option, the closing of such purchase (the “LDPO
Closing”) shall take place at a nationally or regionally recognized title company designated by Tenant on a date designated by Tenant which date shall be no more than sixty (60) days after the date of Tenant’s exercise notice. At
the LDPO Closing, Landlord shall convey the Property and any improvements thereon to Tenant by special warranty deed in form reasonably acceptable to Tenant, subject only to the title exceptions set forth on Exhibit “C” attached hereto and
incorporated herein (subject to the terms and conditions set forth at Section 46 hereof, the “Title Exceptions”), but specifically excluding any and all Fee Mortgages (as hereinafter defined) and monetary liens (other than
ad valorem taxes for the year in which the LDPO Closing takes place which are to be prorated as set forth below), but together with such easements benefiting the Premises and any other subsequent matters approved or consented to by Tenant,
which consent Tenant shall not unreasonably withhold, condition or delay, all matters created by, caused by or resulting from the acts or omissions of Tenant, anyone claiming under Tenant, or their respective agents or employees, and the exception
for liens securing ad valorem taxes shall be limited to the year in which the LDPO Closing takes place, with the ad valorem taxes for such year to be prorated at the LDPO Closing based upon the most current available taxes. Landlord shall pay any
and all Pennsylvania Realty Transfer Tax which may be due and payable in connection with the transfer of the Property and improvements to Tenant pursuant to this Section 3.2(c). In addition, unless and to the extent that Tenant elected to cause
the work to be stopped pursuant to Section 3.2(b) above or to terminate any Construction Contract, Tenant Improvements Construction Contract or any third party agreement, if requested by Tenant, at its option, Landlord shall assign to Tenant,
and Tenant 

  
 9 

 
shall assume, all the contracts and agreements relating to the construction of the improvements on the Property and not elected to be terminated by Tenant in accordance herewith (including but
not limited to agreements with architects, engineers, and the general contractor) at the LDPO Closing; following which assignment (and any such assignment documents shall expressly provide that) Landlord shall, to the extent permitted under the
contracts and agreements assigned, be released from all further liability thereunder arising and accruing after the date of such assignment, and Tenant shall agree to indemnify, hold harmless and defend Landlord from and against any and all claims,
losses, costs, damages and liabilities arising and accruing under or in connection with such contracts and agreements following the effective date of any such assignment. 
 (e) Landlord Guarantor Guaranty. Contemporaneously with the execution and delivery of this Lease, Landlord shall cause John J. Ferchill (“Landlord Guarantor”) to execute and deliver to
Tenant the Guaranty in the form attached hereto as Exhibit “E” (the “Landlord Guaranty”). Landlord hereby represents and warrants to Tenant that the Landlord Guarantor will be the same and only guarantor of completion under any
guaranty of completion required by any of Landlord’s Fee Mortgagees (as hereinafter defined), and if and to the extent that any other guarantors of completion are required by any such Fee Mortgagee, Landlord agrees to promptly provide and
additional Landlord Guaranty from such other persons or entities in the same form attached hereto as Exhibit “E”. Landlord hereby agrees to provide a written certification to Tenant, within ten (10) days after closing of a loan with
each Fee Mortgagee certifying as to all persons and entities required by any such Fee Mortgagee to guaranty completion of the Improvements and the Tenant Improvements. Failure of Landlord to timely provide such certification and /or to provide,
within ten (10) days after the closing of any loan with a Fee Mortgagee, an additional Landlord Guaranty (or an Amended and Restated Landlord Guaranty, as determined by Tenant) from each such other person or entity guarantying the Fee Mortgagee
shall, upon an additional ten (10) days written notice from Tenant, constitute a Landlord Default hereunder and entitle Tenant, at its option, to terminate this Lease, in which event all further rights and obligations of the parties hereunder
will terminate, except that Landlord shall convey to Tenant the Land for the purchase price paid by Landlord to MSA under the Option Agreement and Landlord shall pay all transfer taxes payable in connection with such conveyance. 

3.3 OPTION TO EXTEND. So long as no Event of Default by Tenant then exists pursuant to the terms and
conditions of this Lease (at either the time of Tenant’s exercise of its option hereunder, or as of the commencement of any Extension Term as hereinafter defined), Tenant shall have the option to extend the term of this Lease for two
(2) five (5) year periods and a third period of approximately four (4) years and eleven (11) months ending at the end of the 11th full month after the 29th anniversary of the Commencement Date, (each an
“Extension Term”), commencing when the Initial Term of this Lease expires, upon the following terms and conditions. As used in this Lease, the word “Term” shall mean the Initial Term and, to the extent applicable, each
Extension. Term. 
 (a) Tenant shall give to Landlord, on a date which is prior to the date that the applicable Extension
Term would commence (if exercised) by at least three hundred sixty (360) days, a written notice of the exercise of the option to extend the Lease for said Extension Term. 

  
 10 

 
Such notice shall be given in accordance with the requirements of Section 31 hereof. If notification of the exercise of an option is not so given and received, Landlord shall provide written
notification that such Extension option will expire unless exercised within ten (10) business days thereafter, and if not thereafter exercised, all options granted to Tenant pursuant to this Section 3.3 shall automatically expire.

 (b) All of the terms and conditions of the Lease, except where specifically modified by Section 5.2 below, shall apply
to each Extension Term. 
 (c) Tenant shall be permitted to exercise its option to extend the Term pursuant to this
Section 3.3 as to less than the entire Building; provided, however, that: (i) Tenant’s notice in accordance with Section 3.3(a) must indicate the specific portion(s) of the Building to which the Extension Term shall relate;
provided, however, that in no event shall Tenant be entitled to exercise its option to extend in accordance with this Section 3.3 as to less than any entire floor within the Building; (ii) all portions of the Premises to which the
Extension Term shall not apply shall be tendered to Landlord by Tenant in a condition consistent with the requirements set forth at Section 16 of this Lease at the expiration of the then existing Term or Extension Term; and (iii) Landlord
and Tenant shall execute an amendment to this Lease, which amendment shall, as of the commencement of the Extension Term: (A) adjust Tenant’s Base Rent; (B) adjust the definition and depiction of the Premises; (C) establish the
terms and conditions pursuant to which Tenant shall pay its pro-rata share of all Property Costs and Taxes (as hereinafter defined at Section 5.3), and account for the creation of common areas upon the Premises and within the Building as may be
necessary; and (D) establish all other requisite revisions hereto necessitated pursuant to Tenant’s extension of the Term as to less than all of the Premises in accordance with this Section 3.3. Such amendment to lease shall not be a
condition to the exercise of such removal hereunder but shall be a continuing obligation of Landlord and Tenant until completed. 
 3.4 OPTION TO TERMINATE. Tenant shall have the right to terminate this Lease, effective as of the last day of the tenth (10th) Lease Year (the “Termination Effective Date”), by giving written notice to Landlord of its
election to so terminate no later than the first day of the calendar month that is eighteen (18) months preceding the Termination Effective Date. Upon Tenant’s exercise of its termination option hereunder, a termination fee (the
“Termination Fee”) shall automatically become due from Tenant to Landlord in an amount equal to 100% of the then unamortized principal balance of each of: (a) the Tenant Improvement Allowance of $50/square foot set forth on
Exhibit “D” attached hereto and incorporated herein on the Termination Effective Date and (b) the brokerage commissions paid by Landlord in connection with this Lease ($11.46/square foot, as set forth on Exhibit “D” attached
hereto and incorporated herein as of the Termination Effective Date), which items set forth at subsections 3.4(a) and (b) hereof shall be amortized on a mortgage amortization basis assuming an amortization period of one hundred eighty
(180) months beginning as of the Commencement Date, and an imputed interest rate of eight percent (8%) per annum. Based on a total rentable square footage within the Building of 118,031 rentable square feet and the terms of Exhibit
“D”, the Termination Fee payable on the Termination Effective Date (the last day of tenth (10th) Lease Year after the Commencement Date) would be $3,418,739. In the event that Tenant exercises its termination 

  
 11 

 
option pursuant to this Section 3.4, Tenant shall pay to Landlord the Termination Fee on or before the Termination Effective Date. In the event that the Termination Fee is not timely paid by
Tenant, Landlord shall provide Tenant with not less than ten (10) days written notice of such failure to pay, and if Tenant does not thereafter pay the same within such ten (10) day period, Tenant’s right to terminate this Lease in
accordance with this Section 3.4 shall be deemed void, invalid and of no force or effect, and this Lease shall continue in full force and effect without regard to this Section 3.4. 
 4. USE AND OCCUPANCY OF PREMISES. 
 4.1 USE. Tenant and, to the
extent permitted by Tenant, any subtenants of the Premises (who are permitted subtenants in accordance with Article 13 hereof) and all contractors, subcontractors, licensees and invitees of Tenant or any such subtenant, and all agents,
representatives and employees of anyone or more of the foregoing (collectively, the “Tenant’s Permitees”) may use the Premises solely for general office purposes, and at Tenant’s option, for “Test Bed and Shop Floor
Purposes” (as defined herein) and uses incidental to all of the foregoing, and for no other purpose whatsoever (“Permitted Uses”). For purposes hereof, the term “Test Bed and Shop Floor Purposes” shall mean the
right to establish an area or areas in the Premises and use the same for the storage, assembly, disassembly, installation, testing, downloading and uploading of software and shipping of certain computers and computer components and accessories and
other equipment used, offered or otherwise sold or leased in connection with Tenant’s business. Such use shall include the right to construct a raised floor area and to install racks and cabling for use with such equipment, computers and
computer components. Tenant shall not use the Premises for any use or purpose other than the Permitted Uses without the consent of Landlord, which shall not be unreasonably withheld, delayed or conditioned. 

Neither Tenant nor Landlord shall initiate, submit an application for, or otherwise request, any variance, conditional use permit, subdivision or
rezoning application for the Premises, without first obtaining the other’s prior written consent, which shall not be unreasonably withheld, delayed or conditioned; provided, notwithstanding anything to the contrary set forth above, Landlord
shall not seek a subdivision of the Land during the Term of this Lease, including all Extensions hereof. 
 Without limitation of the foregoing,
neither Tenant nor any of Tenant’s Permittees shall: (a) place loads upon floors, walls or ceilings in excess of the load such items were designed to carry; (b) place or store, nor permit any other person or entity to place or store,
any property, equipment, materials, supplies or other items outside of the Building in violation of any law; (c) except for signage that may be permitted by Landlord pursuant to Section 21 hereof, change the exterior of the Building in any
material respect; or (d) use or occupy the Premises in any manner deemed in good faith by Landlord’s insurance company to be an unreasonable fire or safety hazard. If Tenant’s or Tenant’s Permittees’ use or occupancy of the
Premises shall cause an increase in the cost to Landlord of any insurance over and above the normal cost of such insurance for the type and location of the Building, Tenant shall, on demand and as Additional Rent, reimburse Landlord for such excess
cost, and Tenant or Tenant’s Permittees shall 

  
 12 

 
discontinue any use or occupancy (including the removal of equipment or materials) which shall have resulted in the increase of the cost of said insurance to Landlord, unless Landlord shall
thereafter consent to such use in writing. 
 4.2 COMPLIANCE WITH LAWS. Tenant and Tenant’s Permittees shall, at
their sole expense, promptly comply with all applicable laws, ordinances, rules, regulations, orders, certificates of occupancy, conditional use or other permits, variances, covenants, conditions, restrictions, easements, together with the Plan, the
Declaration and all requirements of any insurance underwriters, rating bureaus or government agencies, now in effect or which may hereafter come into effect, relating in any manner to the occupation and use by Tenant or Tenant’s Permittees of
the Premises (collectively, the “Requirements”), except for obligations of Landlord in connection with the construction of the Building, other Improvements and Tenant Improvements, respectively, and with reference to any maintenance
and repair and other obligations of Landlord hereunder, including all requirements of the Americans With Disabilities Act that relate to the Building, other Improvements and the Tenant Improvements; Tenant shall only be responsible for any
requirements associated with any Alterations (as hereinafter defined), or related to Tenant’s or Tenant’s Permittees business operations at the Premises, and all federal, state and local laws and regulations governing occupational safety
and health related to Tenant’s use of the Premises. Neither Tenant not Tenant’s Permittees shall permit any objectionable or unpleasant odors, smoke, dust or gas to emanate in any material respect outside of the Premises, or take any other
action that would constitute a nuisance or would disturb in any material respect, unreasonably interfere with or endanger Landlord or other persons or property of other persons within the Building or otherwise upon the Premises. Tenant and
Tenant’s Permittees shall obtain, at Tenant’s sole expense, any permit or other governmental authorization required to operate their business upon the Premises. 
 4.3 ENVIRONMENTAL COMPLIANCE. 
 (a) Tenant and Tenant’s Permittees
shall keep the Premises free of and shall promptly and diligently remove any Hazardous Substances introduced to the Premises by Tenant during the Term, in accordance with all applicable Requirements, and shall not, and shall cause Tenant’s
Permittees not, to store, use, discharge or dispose of any Hazardous Substances in, on or from the Premises or other portions of the Premises. Without limiting the foregoing restriction, Tenant shall, and shall cause all of Tenant’ s Permittees
to use, dispose of and transport all Hazardous Substances in accordance with all applicable Requirements. “Hazardous Substances” shall mean asbestos, asbestos-containing materials, polychlorinated biphenyls, mercury, lead,
lead-based paint, chlorofluorocarbons, petroleum-based products, petroleum byproducts, explosives and other substances regulated by the Comprehensive Environmental Response, Compensation and Liability Act of 1980, 42 U.S.C. Section 9601 et
seq., the Resources Conservation and Recovery Act, 42 U .S.C. Section 6901 et seq., or any other federal, state or local laws, rules, regulations or ordinances relating to the regulation of toxic or hazardous materials or otherwise to the
environment, all as the same may have heretofore been or may hereafter be amended. Notwithstanding the foregoing, Tenant shall be permitted to use and store on the Premises reasonable quantities of petroleum products (including, without limitation,
heating oil), cleaning materials and other substances which fall within the definition 

  
 13 

 
of “Hazardous Substance” to the extent reasonably necessary for the operation or the maintenance of the Premises and/or the operation of its business so long as such use and storage and
the disposition thereof is in compliance with applicable Requirements. Tenant shall indemnify, defend and hold Landlord and its officers, directors, managers, agents, shareholders, partners, members, trustees, beneficiaries and all other persons
with interests, directly or indirectly, in Landlord, and the respective agents and employees of each of the foregoing (collectively, the “Landlord Parties”) harmless against and from any liability, damage, claim, cost or expense
whatsoever (including reasonable attorneys’ fees) resulting from any noncompliance with the terms of this Section 4.3 or arising out of or in any way connected with placing, storing, installing, discharging, releasing or generating by or
on behalf of Tenant or any Tenant Permittee on, in, under or about the Premises, any Hazardous Substances during the Term. 

(b) Upon not less than ten (10) days prior written notice from Landlord and so long as the same does not unreasonably interfere with
Tenant’s use and occupancy and business operations at the Premises, Tenant shall permit such persons as Landlord may designate (“Site Reviewers”) to visit the Premises during normal business hours and in a manner which does not
unreasonably interfere with Tenant’s operations and perform, as agents of Tenant, and to conduct environmental site investigations and assessments (“Site Assessments”) on the Premises in any of the following circumstances:
(i) in connection with any sale, financing or refinancing of the Premises; (ii) within the six month period prior to the expiration of the Term; (iii) if required by Landlord’s Fee Mortgagee (as hereinafter defined at
Section 20) or the terms of any credit facility to which Landlord is bound; (iv) if an Event of Default exists; or (v) at any other time that, in the opinion of Landlord, a reasonable basis exists to believe that a violation or any
environmental regulation, or any condition that could reasonably be expected to result in any violation or an environmental regulation exists. Such Site Assessments may include both above and below the ground testing for Hazardous Substances and
such other tests as may be necessary, in the opinion of the Site Reviewers, to conduct the Site Assessments. Tenant shall supply to the Site Reviewers such historical and operational information regarding the Premises as may be reasonably requested
by the Site Reviewers to facilitate the Site Assessments, and shall make available for meetings with the Site Reviewers appropriate personnel having knowledge of such matters. The cost of performing and reporting Site Assessments shall be paid by
Landlord. 
 (c) Notwithstanding anything to the contrary set forth in this Lease, in the event that: (i) any Hazardous
Materials upon the Premises pre-exist Substantial Completion by Landlord of all the Improvements and Tenant Improvements and delivery of the Premises to Tenant and Tenant’s occupancy and use of all the Premises in violation of any applicable
environmental law, by reason other than a breach of Tenant’s or Tenant’s Permittees’ obligations pursuant to this Lease (any such violation being hereinafter designated as an “Existing Release”) or (ii) any
Hazardous Materials are otherwise placed upon by, or result from, the acts or omissions of Landlord or its agents, employees or contractors, including but not limited to the performance by Landlord of its repair and maintenance obligation and/or any
of its other obligations hereunder (“Landlord Release”), Landlord shall, at its sole cost and expense, indemnify, defend and hold harmless Tenant, its employees, agents, officers and directors from

  
 14 

 
and against any claims, demands, penalties, fines, liabilities, settlements, damages, costs or expenses arising out of or in any way related to the presence of the Existing Release and/or a
Landlord Release. 
 4.4 USE AS INTENDED. Tenant shall cause all rubbish, trash, garbage, discarded containers, materials
or equipment, and other refuse to be stored in fire-proof bins while awaiting its removal. Tenant shall place recyclable trash in designated bins. Tenant shall not unreasonably obstruct any sidewalks, common areas, driveways and parking areas in or
on the Premises. Tenant shall not place, store or stage any inventory, supplies, pallets, trash or other items or materials in the parking lot or any other area outside of the Premises. The toilet rooms, water-closets, sinks, water coolers, other
water apparatus and the Building’s heating, plumbing, ventilation, electrical and air conditioning systems shall not be used for any purposes other than those for which they were constructed or intended, and no sweepings, rubbish, or refuse
shall be thrown or placed therein. Except for signs expressly authorized by the terms of this Lease, Tenant shall not place anything on the outside of the Building or Leased Premises or otherwise in a location visible from outside the Building or
Premises. Tenant shall not keep or conduct in, on, or about the Premises or any other portion of the Premises any article or activity which, in Landlord’s reasonable, good faith judgment, has or causes an offensive odor or noise, is of an
explosive, dangerous or hazardous nature, has any other material adverse impact on the appearance, safety, value or operation of the Premises, without the prior express written consent of Landlord. Notwithstanding anything to the contrary contained
in this Section 4.4 and so long as Tenant and/or Tenant’s Permittees are the sole occupant(s) of the Premises, Tenant and Tenant’s Permittees shall only be responsible for the requirements of the first sentence of this
Section 4.4. 
 4.5 TENANT’S PERMITTEES. Tenant’s Permittees shall comply with all of the terms of this
Section 4 in the same manner, and to the same extent, as required of Tenant. 
 5. RENT; PROPERTY COSTS. 

5.1 BASE RENT DURING INITIAL TERM. 
 (a) Commencing as of the Commencement Date, and continuing through the last day of the fifth (5th) Lease Year, Tenant shall pay to Landlord annual fixed minimum rent (“Base Rent”) in the amount of
$25.04 per rentable square foot of the Premises, as such square footage is determined in accordance with the terms of Section 2 of this Lease; 
 (b) Commencing as of the first day of the sixth (6th) Lease Year, and continuing through the last day of the tenth
(10th) Lease Year, Tenant shall pay to Landlord Base
Rent in the amount of $26.04 per rentable square foot of the Premises; and 
 (c) Commencing as of the first
day of the eleventh (11th) Lease Year, and continuing
through the expiration of the Initial Term, Tenant shall pay to Landlord Base Rent in the amount of $27.04 per rentable square foot of the Premises. 

  
 15 

 (d) Tenant promises to pay to Landlord in advance, without demand,
deduction, set-off or counterclaim except as otherwise expressly permitted hereunder, equal monthly installments of Base Rent on or before the first (1st) day of each calendar month in which Base Rent is due; provided, however, that if the Commencement Date shall be
other than the first (e) day of a calendar month, then for such partial month, Tenant shall, pay to Landlord on the Commencement Date a pro rata portion of the monthly installment of Base Rent for the first Lease Year, such pro rata portion to
be calculated on the number of days remaining in such partial month from and after the Commencement Date. All payments required to be made by Tenant to Landlord hereunder shall be payable at such address as is set forth at Section 31 hereof, or
at such other address as Landlord may specify from time to time by written notice delivered in accordance herewith. 
 5.2
BASE RENT DURING EXTENS101V TERMS. 
 (a) The Base Rent payable during each respective Extension Term shall be calculated
as of the commencement of each such Extension Term, and shall be in an amount equal to one hundred percent (100%) of the actual Market Rate on the date the then-current Extension Term commences. The term “Market Rate” shall
mean the annual amount per rentable square foot that a willing, comparable renewal tenant would pay and a willing, comparable landlord of a comparable office building in the comparable markets of the Pittsburgh Region would accept at arm’s
length for similar space, giving appropriate consideration to the following matters: (i) the date of commencement of such Extension Term; (ii) annual rental rates per rentable square foot; (iii) the type of escalation clauses
(including, but without limitation, operating expense, real estate taxes, and CPI) and the extent of liability under the escalation clauses (i.e., whether determined on a “net lease” basis or by increases over a particular base year or
base dollar amount); (iv) rent abatement provisions reflecting free rent and/or no rent during the lease term; (v) tenant improvement allowances; (vi) credit worthiness of Tenant; (vii) length of lease term; (viii) size and
location of premises being leased; and (ix) other generally applicable terms and conditions of tenancy for similar office space; provided, however, Tenant shall not be entitled to any tenant improvement or refurbishment allowance of any type.
The Market Rate may also designate periodic rental increases and similar economic adjustments. The Market Rate shall be the Market Rate in effect as of the beginning of the applicable Extension Term, even though the determination may be made in
advance of that date, and the parties may use recent trends in rental rates in determining the proper Market Rate as of the beginning of each Extension Term. For purposes of the Lease, “Pittsburgh Region” shall mean the metropolitan
statistical area of Pittsburgh, Pa., as defined by the United States Office of Management and Budget, and “Comparable Markets” as used in the Lease shall mean other Class A office complexes in the real estate submarkets of the
Pittsburgh Region, with reference to the following factors: (i) building quality; (ii) suburban market location; and (iii) surrounding tenant amenities. 
 (b) If Tenant exercises its option to extend the Term pursuant to Section 3.3 hereof, Landlord shall determine the Market Rate by using its good faith judgment, and shall

  
 16 

 
provide Tenant with written notice (“Initial Notice”) of such amount within thirty (30) days after Landlord receives Tenant’s notice to extend the Term. Tenant shall have
thirty (30) days (“Tenant’s Review Period”) after receipt of Landlord’s notice of the new rental within which to accept such Market Rate. In the event Tenant fails to reject, in writing, the Market Rate proposal by
Landlord during Tenants Review Period, then such proposal shall be deemed accepted. In the event that Tenant rejects, in writing, such Market Rate proposal during Tenant’s Review Period, (i) Tenant may, by written notice prior to the
expiration of Tenant’s Review Period, rescind its exercise of its option to extend the Term, in which event such exercise of the extension right shall be null and void ab initio and the lease will terminate at the expiration on the then current
Term or Extension Term, subject to holdover in accordance with Section 16.3 below, or (ii), if the extension option is not rescinded, Landlord and Tenant shall attempt to agree upon such Market Rate, using their best good faith efforts and
subject to the terms set forth at Section 5.2(d) below. If Landlord and Tenant fail to reach agreement within ten (10) days following Tenant’s Review Period (the “Outside Agreement Date”), then each party shall place
in a separate sealed envelope their final proposal as to the Market Rate, and such determination shall be submitted to arbitration in accordance with Sections 5.2(c)(i) through (v) below. In the event that Landlord fails to timely generate the
Initial Notice of Landlord’s opinion of the Market Rate on or before the day that is thirty (30) days after Tenant’s notice to extend, then Tenant may commence such negotiations by providing the Initial Notice, in which event Landlord
shall have ten (10) days (“Landlord’s Review Period”) after receipt of Tenant’s Initial Notice of the new Market Rate within which to accept such Market Rate. In the event Landlord fails to accept in writing such
Market Rate proposed by Tenant, then such proposal shall be deemed rejected, and Landlord and Tenant shall attempt in good faith to agree upon such Market Rate, using their best good faith efforts. If Landlord and Tenant fail to reach agreement
within ten (10) days following Landlord’s Review Period (which shall be, in such event, the “Outside Agreement Date” in lieu of the above definition of such date), then each party shall place in a separate sealed envelope their
final proposal as to Market Rate, and such determination shall be submitted to arbitration in accordance with Sections 5.2(c)(i) through (v) below. 
 (c) ARBITRATION OF DISPUTES 
 (i) LANDLORD AND TENANT SHALL MEET WITH EACH OTHER
WITHIN FIVE (5) BUSINESS DAYS AFTER THE OUTSIDE AGREEMENT DATE AND EXCHANGE THEIR SEALED ENVELOPES AND THEN OPEN SUCH ENVELOPES IN EACH OTHER’S PRESENCE. IF LANDLORD AND TENANT DO NOT MEET WITHIN SAID FIVE (5) BUSINESS DAY PERIOD OR
DO NOT MUTUALLY AGREE UPON THE MARKET RATE WITHIN ONE (1) BUSINESS DAY OF THE EXCHANGE AND OPENING OF ENVELOPES, THEN, WITHIN TEN (10) BUSINESS DAYS AFTER THE FIFTH BUSINESS DAY WITHOUT MEETING OR THE EXCHANGE AND OPENING OF ENVELOPES,
WHICHEVER IS APPLICABLE, LANDLORD AND TENANT SHALL AGREE UPON AND JOINTLY APPOINT A SINGLE ARBITRATOR WHO SHALL BY PROFESSION BE A REAL ESTATE BROKER OR AGENT WHO SHALL HAVE BEEN ACTIVE OVER THE FIVE (5) YEAR PERIOD ENDING ON THE DATE OF SUCH

  
 17 

 
APPOINTMENT IN THE LEASING OF BUILDINGS SIMILAR TO THE PREMISES IN THE GEOGRAPHICAL AREA OF THE PREMISES. NEITHER LANDLORD NOR TENANT SHALL CONSULT WITH SUCH BROKER OR AGENT AS TO HIS OR HER
OPINION AS TO THE MARKET RATE PRIOR TO THE APPOINTMENT. THE DETERMINATION OF THE ARBITRATOR SHALL BE LIMITED SOLELY TO THE ISSUE OF WHETHER LANDLORD’S OR TENANT’S SUBMITTED MARKET RATE FOR THE PREMISES IS THE CLOSEST TO THE ACTUAL MARKET
RATE FOR THE PREMISES AS DETERMINED BY THE ARBITRATOR, TAKING INTO ACCOUNT THE REQUIREMENTS FOR DETERMINING MARKET RATE SET FORTH HEREIN. SUCH ARBITRATOR MAY HOLD SUCH HEARINGS AND REQUIRE SUCH BRIEFS AS THE ARBITRATOR, IN HIS OR HER SOLE
DISCRETION, DETERMINES IS NECESSARY. IN ADDITION, LANDLORD OR TENANT MAY SUBMIT TO THE ARBITRATOR, WITH A COPY TO THE OTHER PARTY, WITHIN FIVE (5) BUSINESS DAYS AFTER THE APPOINTMENT OF THE ARBITRATOR ANY MARKET DATA AND ADDITIONAL INFORMATION
SUCH PARTY DEEMS RELEVANT TO THE DETERMINATION OF THE MARKET RATE (“RR DATA”), AND THE OTHER PARTY MAY SUBMIT A REPLY IN WRITING WITHIN FIVE (5) BUSINESS DAYS AFTER RECEIPT OF SUCH RR DATA. FAILURE OF EITHER PARTY HERETO TO
SUBMIT A MARKET RATE OR OTHERWISE PARTICIPATE WILL NOT PREVENT THE SINGLE ARBITRATOR FROM RENDERING A DECISION (EVEN IF BASED ON INFORMATION PROVIDED ONLY BY ONE OF THE PARTIES). 

(ii) THE ARBITRATOR SHALL, WITHIN THIRTY (30) DAYS OF HIS OR HER APPOINTMENT, REACH A DECISION AS TO WHETHER THE PARTIES SHALL USE
LANDLORD’S OR TENANTS SUBMITTED MARKET RATE AND SHALL NOTIFY LANDLORD AND TENANT OF SUCH DETERMINATION. 
 (iii) THE
DECISION OF THE ARBITRATOR SHALL BE FINAL AND BINDING UPON LANDLORD AND TENANT; 
 (iv) IF LANDLORD AND TENANT DO NOT AGREE ON A
SINGLE ARBITRATOR WITHIN SAID 10 BUSINESS DAY PERIOD, EACH SHALL WITHIN THREE (3) BUSINESS DAYS THEREAFTER APPOINT A REAL ESTATE BROKER (EACH, AN “APPOINTED BROKER” AND TOGETHER, THE “APPOINTED BROKERS”) MEETING REQUIREMENTS
OF THE SINGLE ARBITRATOR SET FORTH ABOVE AND NOTIFY THE OTHER PARTY OF THE IDENTITY AND CONTACT INFORMATION OF ITS APPOINTED BROKER, AND THE TWO APPOINTED . BROKERS SHALL MUTUALLY AGREE ON THE SINGLE ARBITRATOR (WHO SHALL MEET THE REQUIREMENTS ABOVE
FOR THE SINGLE ARBITRATOR) WITHIN THREE (3) BUSINESS DAYS AFTER THEIR APPOINTMENT; IF EITHER PARTY SHOULD FAIL TO TIMELY APPOINT AND NOTIFY THE OTHER PARTY OF ITS APPOINTED BROKER, THE BROKER SO TIMELY APPOINTED BY THE ONE PARTY (WITH TIMELY
NOTICE THEREOF TO THE OTHER PARTY) SHALL BE THE SINGLE ARBITRATOR. 

  
 18 

 (v) THE COST OF THE ARBITRATION SHALL BE PAID BY LANDLORD AND TENANT EQUALLY. 

NOTICE: BY INITIALING IN THE SPACE BELOW YOU ARE AGREEING TO HAVE ANY DISPUTE ARISING OUT OF THE MATTERS INCLUDED IN THE
“ARBITRATION OF DISPUTES” PROVISION DECIDED BY NEUTRAL ARBITRATION AS PROVIDED BY PENNSYLVANIA LAW AND YOU ARE GIVING UP ANY RIGHTS YOU MIGHT POSSESS TO HAVE THE DISPUTE LITIGATED IN A COURT OR JURY TRIAL BY INITIALING IN THE SPACE BELOW
YOU ARE GIVING UP YOUR JUDICIAL RIGHTS TO DISCOVERY AND APPEAL, UNLESS THOSE RIGHTS ARE SPECIFICALLY INCLUDED IN THE “ARBITRATION OF DISPUTES” PROVISION. YOUR AGREEMENT TO THIS ARBITRATION PROVISION IS VOLUNTARY. 

WE HAVE READ AND UNDERSTAND THE FOREGOING AND AGREE TO SUBMIT DISPUTES ARISING OUT OF THE MATTERS INCLUDED THE “ARBITRATION OF
DISPUTES” PROVISION TO NEUTRAL ARBITRATION. 
  

					
	  
	 		 	  

	(Landlord initials)	 		 	(Tenant initials)
			
	  
	 		 	  

	(Landlord initials)	 		 	(Tenant initials)

 5.3 TAXES. 
 (a) Payment of Taxes. Landlord shall forward copies of all bills or statements for Taxes to Tenant promptly upon receipt thereof Landlord further agrees to cooperate with Tenant to cause all tax
bills (or copies thereof) to be sent directly to Tenant during the Term, if and to the extent permitted by the taxing bodies. Taxes, as hereinafter defined, for the Premises accruing during the Term are the responsibility of Tenant, and to the
extent Taxes for the Premises are abated, reduced or limited during the Term for any reason, including but not limited to, the designation of the Premises as a Strategic Development Area pursuant to the Governor of the Commonwealth of
Pennsylvania’s designation by Executive Order, such benefit, if any, of the abatement, reduction or limitation will inure to the benefit of Tenant to the extent arising or accruing prior to the expiration or termination of the Term. Following
such receipt of copies of the bills or statements, Tenant shall cause all Taxes imposed on the Premises to be paid in a timely manner directly to the applicable taxing authority. Unless Tenant contests the amount of the Taxes pursuant to the terms
of subsection 5.3(b) below, Tenant shall pay all such Taxes prior to the date the same shall become delinquent and shall deliver to Landlord a receipt evidencing payment of the Taxes. In the event that Tenant fails to pay the Taxes in a timely
manner as prescribed by applicable Law, Landlord shall have the right to pay such Taxes, and Tenant shall pay to Landlord, as Additional Rent, the amount of such taxes paid by Landlord, together with an administrative charge of five percent
(5%) of the amount of such taxes paid, provided that no such five (5%) penalty shall be due or owing unless Landlord shall have first given Tenant such notice and opportunity to cure such failure to pay as may be required for such failure
to be an 

  
 19 

 
Event of Default. In the event that the Term begins or ends on a date other than the first or last day of a tax year, respectively, the amount of Taxes, if any, payable by Tenant for such year
shall be prorated on a per diem basis, and Tenant shall pay such amount to Landlord in equal monthly installments during the portion of the applicable year occurring during the Term and prior to the date such Taxes are due and payable, and Landlord
shall pay to the taxing body such Taxes for such years. The term “Taxes” means all ad valorem real property taxes, charges, impositions, levies, burdens and assessments of every kind and nature and any other impositions and/or
charges imposed in lieu of ad valorem real property taxes. Notwithstanding the foregoing, Taxes shall not include any inheritance, income, franchise, gift, estate, succession, transfer, capital stock or excess profit taxes. If any Taxes can
be paid in multiple installments, Tenant may elect to pay any such Tax in multiple installments prior to the date the same become delinquent. Any refund, rebate, discount, credit or similar amount relating to any Taxes paid by Tenant shall be
promptly paid or credited to Tenant. 
 (b) Contest of Taxes. Tenant, at its expense, shall have the right to contest, by
appropriate proceedings diligently conducted in good faith, either or both (a) the assessed valuation of all or any portion of the Premises or the Building which is reflected by the Taxes, or (b) the real estate tax rate levied against the
Premises or the Building which is reflected by the Taxes, and Landlord shall reasonably cooperate with Tenant in any such contest and, if requested by Tenant, shall file or join in any appeal or contest. 

(c) Recapture of Incentives and Taxes. Tenant has obtained the designation of the Premises as a Strategic Development Area and has
obtained or may in the future obtain or seek to obtain governmental and other third party payments, credits, abatements, refunds, rebates, grants, financial concessions, tax relief, tax reductions, tax deferments, or other incentives relating to the
Premises which will inure to the benefit of Tenant (hereinafter referred to as the “Incentives”). Unless and to the extent caused by the negligence or willful misconduct of Tenant, Landlord shall be solely responsible to make any
required refund of the Incentives, and Landlord shall be solely responsible for any additional, catch-up or roll-back Taxes which may be payable as a result of the grant of the Incentives, and for the payment of any required refund or recapture of
Taxes and/or other taxes payable to any governmental body which were reduced, rebated, deferred or lost and Landlord does hereby agree to indemnify and hold Tenant harmless from and against any and all loss, cost, damage and expense, including
without limitation court costs and reasonable attorneys’ fees, suffered or incurred by Tenant as a result thereof. 
 5.4
DEFINITION AND PAYMENT OF ADDITIONAL RENT. In addition to all Base Rent due hereunder, any other sums of money, charges or other amounts, of every nature and type whatsoever, required to be paid by Tenant to Landlord pursuant to this Lease,
shall collectively be deemed to constitute “Additional Rent”. Non-payment of Additional Rent when due, and after the expiration of the applicable cure period, shall, at Landlord’s option, constitute an Event of Default under
this Lease to the same extent as a non-payment of Base Rent, and shall entitle the Landlord to the same remedies as non-payment of any installment of Base Rent. Base Rent and Additional Rent shall hereinafter sometimes be collectively designated as
“Rent”. Except with regard to the payment of Base Rent (all of which Base Rent shall be payable as of 

  
 20 

 
the Commencement Date), Tenant’s obligation to pay all Additional Rent, including without limitation all Taxes, shall commence, on a pro-rata basis, as of each applicable date of Substantial
Completion (as set forth at Section 3.2(c) above). 
 5.5 LATE PAYMENT OF RENT. In the event that any Rent or other
sum payable pursuant to this Lease shall not be paid when due, subject to any applicable Notice and grace period set forth elsewhere in this Lease as a condition to the occurrence of an Event of Default hereunder, Tenant shall pay to Landlord, as
Additional Rent, interest on the past due amount at a per annum rate (the “Default Rate”) equal to two percent (2%) over the prime rate of interest as published from time to time in the Wall Street Journal (or, in the absence
of such publication, in such other publications as Landlord may designate in good faith from time to time), accruing from and after the due date of such payment. In addition, if any Rent or other sum payable pursuant to this Lease shall not be paid
within ten (10) days of the date such payment is due, Tenant shall pay Landlord a late fee in the amount of five percent (5%) of the sum not so paid when due, but in no event more than the amount required to reimburse the Landlord for any
late charges or interest paid to its lender which directly results from the delinquent payment by Tenant of any such sum payable hereunder. Tenant acknowledges that the foregoing late charge is a reasonable charge for the additional internal
administrative costs required of Landlord and late charges that may be incurred by Landlord on its Fee Mortgage by reason of such late payment, but that the payment of such late charge shall not cure any Event of Default or otherwise limit any other
rights or remedies of Landlord. 
 6. SECURITY DEPOSIT. Except as otherwise required elsewhere in this Lease, Tenant shall not be
required to pay a security deposit as of the Effective Date. 
 7. UTILITIES AND SERVICES. 

7.1 TENANT’S RESPONSIBILITY. During the Term, Tenant shall pay for all gas, heat, light, power, water, sewer, telephone or
other communication service, security services, janitorial services, garbage disposal and all other utilities and services of every kind and nature supplied to the Premises. Tenant agrees to supply Landlord, upon Landlord’s written request,
evidence that all municipal water and/or sewer bills have been paid. 
 7.2 INTERRUPTIONS. Landlord shall not be liable
to Tenant, and Tenant shall not be entitled to any abatement of Rent for any loss or damage to Tenant or its property resulting from burst, stopped or leaking utility lines, and Landlord shall not be liable to Tenant for damages or otherwise for any
failure or interruption of any such utility service furnished to the Premises, except where such failure or interruption arises as a result of Landlord’s failure to perform any act it is required to perform under this express terms of this
Lease or otherwise as a result of the negligence or wrongful acts or omissions of the Landlord, its agents, employees or contractors. Except if resulting from a breach by Landlord of its obligations hereunder or as a result of the negligence or
wrongful acts or omissions by Landlord, its agents, employees or contractors, Landlord shall have no liability to Tenant if Tenant is unable to obtain utility services of any kind, for any reason, including, but not limited to, repairs, replacements
or improvements, by any strike, lockout or other labor trouble, by inability to secure electricity, gas, water, telephone 

  
 21 

 
service or other utility at the Premises, by any accident, casualty or event arising from any other cause whatsoever, and such failures shall never be deemed to constitute an eviction or
disturbance of Tenant’s use and possession of the Premises, nor relieve Tenant from the obligation of paying Rent or performing any of its obligations under this Lease. Furthermore, Landlord shall not be liable under any circumstances for loss
of property or for injury to, or interference with, Tenant’s business, including, without limitation, loss of profits, however occurring, through or in connection with or incidental to Tenant’s inability to obtain utility services.

 8. MAINTENANCE AND REPAIRS. 
 8.1 LANDLORD REPAIRS. 
 (a) Landlord shall, at its sole cost and expense,
maintain in good order and repair (as determined by reference to comparable Class A facilities in the Pittsburgh Region) and in accordance with all Laws and Requirements, (i) the roofs (including, without limitation, the structural,
membrane and other elements of the roofs); (ii) the structural soundness of the Building and other Improvements (including, without limitation, interior structural columns, interior load bearing walls, the exterior wall, the foundation, the
footings, the slab and any structural flooring components (but excluding access flooring, raised flooring or floor coverings) and any other structural elements (excluding the generator and HVAC equipment wherever located and the parking lots lights,
and excluding the plumbing and electrical wiring within the Building, but including such plumbing and electrical wiring located outside of the Building); (iii) all components of the Premises if and to the extent covered by any third party
warranties that have not been previously assigned to Tenant under Section 8.3 below; (iv) any and all repairs and replacements necessitated by the negligence or willful misconduct of Landlord or Landlord’s agents, employees, licenses
or invitees and (v) all other items, if any, as are the express responsibility of Landlord under this Lease. In addition, Landlord shall be responsible, at its sole cost and expense, for paying to Tenant the Landlord’s Share of Qualified
Capital Expenses pursuant to Section 8.2(c) below. Notwithstanding anything to the contrary set forth in this Section 8.1(a), however, Landlord shall not be obligated to perform any maintenance or repairs required to the Premises as a
result of the negligence or willful misconduct of Tenant or Tenant’s Permittees, or by any act or omission of tenant or Tenant’s Permittees that voids or invalidates any third party warranty otherwise applicable to the portion of the
Premises in need of such maintenance or repair. If any repair which is the responsibility of Landlord under this Section 8.1 is necessitated in any material respect by the default, negligence or intentional misconduct of Tenant or Tenant’s
Permittees, Tenant shall reimburse Landlord, as Additional Rent, for the actual reasonable cost of the portion of such repair necessitated by such default, negligence or intentional misconduct within thirty (30) days of receipt of an invoice
therefor. 
 8.2 TENANT REPAIRS; UTILITIES AND OTHER SERVICES. 

(a) Except for those repairs and replacements to be made by Landlord pursuant to Section 8.1 above, Tenant shall, at its sole cost
and expense, maintain the Premises in good order and repair (as determined by reference to comparable Class A facilities in the 

  
 22 

 
Pittsburgh Region), reasonable wear and tear and damage by casualty and condemnation excepted, including, but not limited to, all necessary repairs and replacements, whether general or special,
ordinary or extraordinary or foreseen or unforeseen and regardless of how the need for such repairs and maintenance arose, including but not limited to those instances of repair where the expenses thereof would be deemed capital in nature, subject
to the provisions of subsection (c) below and including repairs to the generator and HVAC equipment, the parking lot lights and the exterior signage. If any repair which is the responsibility of Tenant under this Section 8.2 is
necessitated in whole or in part by the default, negligence or intentional misconduct of Landlord, its agents, employees or contractors, Landlord shall reimburse Tenant for the actual reasonable cost of the portion of such repair necessitated by
such default, negligence or intentional misconduct within thirty (30) days of receipt of an invoice therefor; provided, however, that prior to commencing any such repair necessitated in whole or in part by the default, negligence or intentional
misconduct of Landlord, its agents, employees or contractors, and so long as such repair or failure to repair does not materially impair Tenant’s use or occupancy of the Premises, Tenant shall provide Landlord with written notice of its
intention to perform such repair, together with a period of thirty (30) days in which to complete same (provided, however, that if such repair is of a type that cannot be completed by Landlord within said thirty (30) days after notice
thereof, then, so long as Landlord commences such cure within said thirty (30) day period and thereafter diligently pursues such cure to completion, such thirty (30) day period shall be extended for such additional period that may be
reasonably required to complete such repair. 
 (b) Except as otherwise expressly provided in this Lease, Tenant shall operate
the Premises, and shall be responsible for the payment of all costs and expenses related to the operation of the Premises, as a Class A facility (as determined by reference to comparable Class A facilities in the Pittsburgh Region), and
shall provide or cause to be provided to the Premises, and shall be responsible for the payment of all costs, expenses, charges, fees and taxes related to providing or causing to be provided to the Premises, all services during the Term (whether or
not the services are billed directly to the Tenant), in accordance with comparable Class A facilities in the Pittsburgh Region, including but not limited to, the following: (i) water, sewer service, gas, fuel, electricity, light, heat,
telephone, television cable, power and other utility service to the Premises, whether or not the services are billed directly to Tenant; (ii) all services necessary for the operation and maintenance of the Premises, including but not limited to
costs of elevator, janitorial, trash removal, security service and other services for the Premises; (iii) costs of maintaining and repairing mechanical systems; and (iv) costs of performing all services necessary for the operation and
maintenance of the Premises, including without limitation the parking lot, driveways, medians and landscaped areas. Tenant shall be entitled to select the service providers of its choice. Tenant shall not be responsible for any charges for utilities
or services used or consumed at the Building or other Improvements prior to the Commencement Date. 
 (c) For purposes of this
Lease, a “Qualified Capital Expense” means any and all costs and expenses necessary to make any repair or replacement to the parking areas and the HVAC equipment: (i) the cost of which for any single item or any series of
Related Repairs 

  
 23 

 
or Replacements (as defined below) exceeds One Hundred Thousand Dollars ($100,000.00), (ii) that is not aesthetic or cosmetic in nature, (iii) that would be classified as a
“capital expense” under generally accepted accounting principles (“GAAP”) or that has a reasonably expected useful life in excess of the then remaining balance of the Term, (iv) that is not required as a result of
Tenant’s willful or negligent act or failure to perform its repair or maintenance obligations in accordance with the requirements of this Lease, (v) that is Tenant’s and not Landlord’s responsibility under this Lease,
(vi) that is not required as a result of casualty or condemnation, (vii) that is made during the last five (5) Lease Years prior to the expiration of the Term (but not including any expenses made prior to any termination of this Lease
as a result of an Event of Default or any expenses made during the last five (5) Lease Years of the then existing Term if the Term is later extended), (viii) that is incurred in connection with the performance of any repair or replacement
which is reasonably necessary and appropriate under the circumstances (provided that Tenant and Landlord shall negotiate in good faith to determine whether any such expense is reasonably necessary and appropriate under the circumstances),
(ix) the need for which is Tenant notifies Landlord of in writing prior to commencing such repair or replacement (except if due to emergency circumstances such prior notice is not reasonably practicable, in which event Tenant shall notify
Landlord in writing as soon as possible after commencing the repair), (x) that, following the expiration of the term of a lease, typically would not be removed in connection with making space available to a new tenant or tenants, and
(xi) Tenant gives Landlord written notice of the cost and expense of which, exclusive of Imputed Interest, setting forth such cost and expense in reasonable detail, within thirty (30) days after completion of such repair or replacement.
“Imputed Interest” shall mean with respect to each item of repair or replacement interest on the unpaid portion of Landlord’s Share of the Qualified Capital Expense thereof from the date of expenditure by Tenant for such repair
or replacement through the date of payment in full by Landlord of Landlord’s Share of such Qualified Capital Expense, calculated at the rate per annum equal to the “prime rate,” as published from time to time in Money Rates column of
The Wall Street Journal. Any and all Qualified Capital Expenses shall be apportioned as between Landlord and Tenant so that Landlord shall pay Landlord’s Share (as hereinafter defined) of such item(s), together with Imputed Interest on
Landlord’s share, and Tenant shall pay the remainder. For purposes of this provision, the term “Related Repairs or Replacements” shall mean two or more repairs or replacements to either such areas or equipment which otherwise
meet the requirements of a Qualified Capital Expense and which are necessitated by the same causal event. “Landlord’s Share” of Qualified Capital Expenses shall be a fraction of all Qualified Capital Expenses, with the
numerator of such fraction being the portion of the useful life of the item paid for by such expense determined in accordance with GAAP that will occur after the expiration of this Lease, and the denominator of such fraction being the useful life of
the item paid for by such expense determined in accordance with GAAP. If such “useful life” cannot be determined under GAAP, then the parties shall utilize the depreciation rules set forth in U.S. Internal Revenue Code and Regulations (as
then supplemented and amended), and if such “useful life” cannot be determined thereunder, then the parties shall utilize a substitute governmental or industry standard for the determination of useful life. Each item of repair or
replacement (including Related Repairs and Replacements) the cost of which is a Qualified Capital Expense shall be performed by the lowest qualified bidder following a competitive bid process (unless Landlord and Tenant mutually approve a higher

  
 24 

 
bidder), unless due to emergency circumstances or otherwise such procedure is not reasonably practicable. Landlord shall pay to Tenant Landlord’s Share of any Qualified Capital Expense,
together with Imputed Interest thereon, within thirty (30) days following the deadline for Tenant to exercise the next succeeding extension right under Section 3.3, but only if such deadline passes without Tenant having exercised such
extension right; provided, if an extension right is exercised for a period after the 2nd Extension Term, and is later rescinded or terminated pursuant to the terms of Section 5.2(b) above, Landlord shall pay to Tenant Landlord’s Share of any Qualified Capital Expenses within thirty
(30) days of such rescission or termination of such extension right. In the event that Landlord fails to timely pay Landlord’s Share of any Qualified Capital Expenses, then Tenant shall have the right to offset the unpaid amount of
Landlord’s Share of such Qualified Capital Expense, together with interest thereon at the Default Rate, against Base Rent accruing thereafter under this Lease. If Landlord’s Share of Qualified Capital Expenses, together with interest
thereon at the Default Rate, exceeds the remaining Base Rent due and owing under this Lease, then Tenant may require prior to the commencement of such work, that Landlord first post a letter of credit or other reasonably acceptable security for such
difference. 
 8.3 WARRANTIES. 
 (a) Capitalized terms set forth in this Section 8.3 which are previously undefined shall have the meanings ascribed thereto in the Work Letter attached to this Lease as Exhibit “B”.

 (b)(i) Landlord warrants the Building, Improvements and Tenant Improvements against defective workmanship and/or materials,
for a period of one (1) year from the date of Substantial Completion, and Landlord agrees, at its sole cost and expense, to repair or replace or to cause the Landlord’s contractor to repair or replace any defective item occasioned by poor
workmanship and/or materials or any such non-compliance during said one (1) year period; Landlord further agrees, at Landlord’s sole cost and expense, to repair and replace, or to cause Landlord’s contractor to repair or replace, any
latent defects in said work and/or materials of which Landlord is notified during the twenty four (24) months after Substantial Completion of all the Improvements and the Tenant Improvements. From and after the expiration of such one
(1) year guaranty of workmanship and materials (and such twenty four (24) months for latent defects), Landlord agrees to cooperate with Tenant in the enforcement by Tenant at Tenant’s cost and expense, of any express warranties or
guaranties of workmanship or materials given by contractors, subcontractors or materialmen that guarantee or warrant against defective workmanship or materials for a period of time in excess of one (I) year period described above (and such
twenty four (24) months for latent defects) and to cooperate with Tenant in the enforcement by Tenant of any service contracts that provide service, repair or maintenance to any item incorporated in the Premises for a period of time in excess
of such one (1) year period (and such twenty four (24) months for latent defects). Landlord’s warranty does not cover ordinary wear and tear, abuse, neglect or general maintenance connected with the Premises, or defects arising from
nature or anything that is beyond the control of the Landlord and/or its contractors. Notwithstanding anything to the contrary set forth herein, Landlord’s warranty, as set forth herein, shall be expressly limited in the following respects:
(i) all materials 

  
 25 

 
shall be in accordance with the Construction Drawings and the Improvements Plans and Specifications and the Tenant Improvements Plans and Specifications and, unless otherwise specified, shall be
as good quality as the market affords in the respective grade specified; and (ii) all materials and mechanical equipment are furnished under manufacturer’s guarantees and liabilities only. In the event of a defect actionable pursuant to
this Section 8.3(b), Tenant’s sole and exclusive remedy against Landlord shall be for the repair and replacement of defects of material and workmanship as provided herein, and except for latent defects, Landlord shall not be responsible
for any defects of any nature in the construction and the Tenant Improvement Work by Landlord about which Landlord is not so notified within said one (1) year period. There are no other express, implied, written or oral warranties, of any kind
or nature, including without limitation any implied conditions or warranties of merchantability or fitness for a particular purpose, made by Landlord pursuant to this Lease, or in connection with the Building, Improvements or Tenant Improvements,
other than those expressly set forth in this Section 8.3(b) and the Workletter attached hereto as Exhibit B. 
 (c)
Landlord hereby agrees that Landlord will attempt to have included in the applicable contracts an agreement that Tenant will be a third party beneficiary of the obligations of the parties other than Landlord under the Construction Contracts, any
architect agreements, all subcontracts and all third party contracts relating in any way to the design or construction of the Improvements and will attempt to have included in each such contract an acknowledgement of such rights of Tenant. Landlord
further agrees that the Construction Contracts, any architect agreements, any development agreement and other third party contracts entered into by Landlord with respect to the design or construction of the Improvements and Base Building Work and/or
the Tenant Improvements and Tenant Improvement Work shall permit the assignment by Landlord to Tenant of such contract upon the exercise by Tenant of the Liquidated Damage Purchase Option. 

(d) As of the date that is one (1) year after Substantial Completion, Landlord shall grant Tenant a nonexclusive assignment, to be
shared in common with Landlord, its successors and assigns, of all warranties and guaranties (except those portions of any warranties and guaranties covering items for which Landlord retains responsibility under Section 8.1 above) obtained by
Landlord from, and all rights of Landlord (except rights with respect to items for which Landlord retains responsibility under Section 8.1 above) with respect to defects in the construction and installation by, the general contractor and any
other contractors, manufacturers, suppliers and vendors of Landlord with respect to the Building, Improvements and Tenant Improvements and any materials used in the construction and installation thereof. In the event that any manufacturer’s
warranty or guaranty is not assignable, Landlord will warrant any items covered thereby until the earlier of one (1) year after Substantial Completion and the expiration of the term of such warranty, and after one (1) year after the
earlier of Substantial Completion and the expiration of the term of such warranty, (i) Tenant, except for items for which Landlord retains responsibility under Section 8.1 above, shall be responsible for such maintenance, repair and
replacement, and (ii) Landlord, at the request of Tenant and at Tenant’s sole cost and expense, will enforce any such unexpired warranties on behalf of, and at the reasonable direction of, Tenant. 

  
 26 

 If in connection with the construction of the Building, other Improvements and the Tenant
Improvements, Landlord has an opportunity to purchase extended warranties or guaranties from the Contractor or any Subcontractor, manufacturer or supplier with respect to any HVAC, plumbing, electrical, mechanical or other systems or any other major
components of the Premises, Landlord shall provide a written notice to Tenant presenting such opportunity. If Tenant wishes for Landlord to purchase such extended warranty or guaranty, Tenant shall provide written notice to Landlord within twenty
(20) days of Landlord’s notice, whereupon Landlord shall purchase such extended warranty or guaranty, the cost of which purchase shall, as a condition to Landlord’s procurement of same, be paid by Tenant as and when such payment is
due from Landlord. 
 8.4 NET LEASE. It is the intent of the parties that this Lease be a net lease to Landlord, and that
except as otherwise expressly set forth herein, Tenant shall be responsible for all maintenance, repair and replacement costs associated with the Premises. Notwithstanding the foregoing, in the event Tenant fails to perform any such required
maintenance, repair and/or replacement within a reasonable period of time as required pursuant to this Section 8, Landlord shall have the right, but not the obligation, to enter upon the Premises, upon written notice to Tenant, and perform such
maintenance, repair and/or replacement on behalf of Tenant, in which event such charges, together with a management fee equal to ten (10%) percent of the cost incurred by the Landlord, shall be deemed Additional Rent due under this Lease and
shall be payable concurrent with the next installment of Base Rent due hereunder. 
 9. INSURANCE. 

9.1 TENANT’S INSURANCE. 
 (a) Except as otherwise provided in subsection (b) below, Tenant shall, at all times during the Lease Term and at Tenant’s sole cost and expense, maintain, or cause to be maintained: 

(i) an “All Risk” Property policy insuring the 100% replacement cost of all of the furniture, trade fixtures and other
personal property of Tenant located in the Premises against loss or damage by fire, theft, flood, earthquake (if available at a commercially reasonable premium in the applicable geographic insurance market), terrorism (if available at a commercially
reasonable premium in the applicable geographic insurance market) and such other risks or hazards as Landlord may reasonably require. 
 (ii) Commercial general public liability and property damage insurance with coverage of not less than $1,000,000.00 per occurrence and $2,000,000 in the aggregate; and Commercial Umbrella or Excess
Liability Insurance, written on an “occurrence basis”, including, without limitation, blanket contractual liability coverage, broad form property damage, independent contractor’s coverage and personal injury coverage, protecting
Landlord and Tenant against liability occasioned by an occurrence on or about the Premises or any appurtenances thereto, the minimum limits for this Commercial Umbrella or Excess Liability policy shall be not less than a combined single limit for
bodily injury (including death) or personal injury and property damage of $10,000,000 per occurrence and $10,000,000 general aggregate. 

  
 27 

 (iii) Workers’ compensation insurance in the amount required by applicable regulations
and employers’ liability insurance covering all persons employed by Tenant in connection with any work done on or about the Premises, or, in lieu of such workers’ compensation insurance, a program of self-insurance complying with the
rules, regulations and requirements of the appropriate agency of the Commonwealth of Pennsylvania. 
 (iv) Comprehensive Boiler
and Machinery/Equipment Breakdown Insurance on any of the equipment on or in the Premises, in an amount not less than $1,000,000.00 per accident for damage to property (and which may be carried as part of the coverage required under clause
(i) above or pursuant to a separate policy or endorsement). Either such Boiler and Machinery policy or the All Risk policy required in clause (i) above shall include at least $1,000,000.00 per incidence for Off-Premises Service
Interruption and $500,000 per incidence for Expediting Expenses. 
 (v) Business Income/Extra Expense Insurance for payments of
Base Rent at limits sufficient to cover 100% of the Base Rent for a period of not less than twelve (12) months from time of loss. 
 (vi) During any period in which substantial Alterations (as hereinafter defined) at the Premises are being undertaken, builder’s risk insurance covering the total completed value with respect to the
improvements being constructed, altered or repaired (on a completed value, non-reporting basis), replacement cost of work performed and equipment, supplies and materials furnished in connection with such construction, alteration or repair of the
improvements, together with such other endorsements as Landlord may reasonably require, and general liability, worker’s compensation and automobile liability insurance with respect to the improvements being constructed, altered or repaired.

 (vii) Such other insurance (or other or different terms with respect to any insurance required pursuant to this
Section 9.1(a), including without limitation amounts of coverage, deductibles, form of mortgagee clause, insurer rating) on or in connection with any of the Premises as Landlord or the mortgagee under any Fee Mortgage may reasonably require,
which at the time is usual and customarily obtained in connection with properties similar in type of building size, use and location to the Premises, as applicable; provided that the insurance requirements under this Article 9 shall not be adjusted
more frequently than once in any give Lease Year. 
 (b) The insurance required by Section 9.1(a) above shall be written by
companies having a rating from Best’s Insurance Reports of A-/IX or above or a long-term insurer financial strength rating of A- or better by Standard & Poor’s Rating Services, a division of the McGraw Hill Companies, Inc. or
equivalent rating agency approved by Landlord and its mortgagee under a Fee Mortgage in their sole, but reasonable, discretion. If said insurance or any part thereof shall expire, be withdrawn, become void, voidable, unreliable or unsafe for any

  
 28 

 
reason, including a breach of any condition thereof by Tenant or the failure or impairment of the capital of any insurer, or if for any other reason whatsoever said insurance shall become
reasonably unsatisfactory to Landlord, Tenant shall promptly obtain new or additional insurance reasonably satisfactory to Landlord. 
 (c) Tenant will use commercially reasonable efforts to provide that each insurance policy referred to in subsections (i), (ii), (iv), (v) and (vi) of Section 9.1(a) above shall contain
standard non-contributory mortgagee clauses in favor of the mortgagee under any Fee Mortgage. In addition, Tenant will endeavor to cause its insurance company to provide that each policy required by any provision of Section 9.1(a) above, except
subsection (iii) thereof, shall provide that such insurance company shall endeavor to give at least thirty (30) days advanced written notice to Landlord and/or the mortgagee under any Fee Mortgage prior to any cancellation, substantial
modification or lapse on any renewal date. 
 (d) Tenant shall pay, or cause to be paid, as they become due all premiums for the
insurance required by Section 9.1(a) above, shall renew or replace each policy and deliver to Landlord certificates of insurance evidencing such coverages. All certificates of insurance (including liability coverage) provided to Landlord and
Lender shall be on standard ACORD Form 28 (or its equivalent, or another commercially reasonable form provided by Tenant). 

(e) Anything in this Section 9.1 to the contrary notwithstanding, any insurance which Tenant is required to obtain pursuant to
Section 9.1(a) above may be carried under a “blanket” policy or policies covering other properties of Tenant or under an “umbrella” policy or policies covering other liabilities of Tenant, as applicable; provided that, such
blanket or umbrella policy or policies otherwise comply with the provisions of this Section 9.1. 
 (f) Tenant shall not
carry separate insurance concurrent in form or contributing in the event of a casualty with that required in this Section 9.1 unless: (i) Landlord and Lender are included therein as named insureds, with loss payable as provided herein; and
(ii) such separate insurance complies with the other provisions of this Section 9.1. Tenant shall immediately notify Landlord of such separate insurance and shall deliver to Landlord the original policies or certified copies thereof.

 (g) The proceeds of any insurance required under Section 9.1(a) above shall be payable as follows: 

(i) proceeds payable under subsections (iii), (iv) and (v) of Section 9.1(a) and proceeds attributable to the general
liability coverage under subsection (vi) of Section 9.1(a) shall be payable to the person entitled to receive such proceeds as set forth under the policy terms and conditions; and 

(ii) proceeds attributable to Builder’s Risk insurance (other than its general liability coverage provisions) and proceeds of
insurance required under subsection (vi) of Section 9.1(a) shall be payable to Landlord or the mortgagee under any Fee Mortgage and applied as set forth in Section 12 hereof. Such proceeds shall be immediately delivered to Landlord or
the mortgagee under any Fee Mortgage, as applicable, if paid to Tenant. 

  
 29 

 (h) Tenant shall furnish Landlord with an appropriate certificate of the effectiveness and
coverage of all polices of insurance required hereunder. In the event that Landlord shall at any time not be in possession of a certificate confirming the then current effectiveness of such insurance, Landlord may obtain such insurance and the
premiums on such insurance shall be deemed Additional Rent payable on demand. 
 9.2 LANDLORD’S INSURANCE. From and
after the Effective Date, Landlord covenants and agrees to provide or cause to be provided, at its expense, but subject to reimbursement by Tenant as set forth herein, and to keep or cause to be kept in force (i) an “All Risk”
property policy (including without limitation from and after the Commencement Date rent loss coverage for a period of at least twelve (12) months) insuring the Premises (including without limitation any Alterations by Tenant of which Landlord
has been given written notice by Tenant) against loss or damage by fire, theft, flood, earthquake (if available at a commercially reasonable premium in the applicable geographic insurance market), terrorism (if available at a commercially reasonable
premium in the applicable geographic insurance market) and such other risks or hazards, in an amount not less than 100% of the replacement cost of the Premises (including without limitation any Alterations by Tenant of which Landlord has been given
written notice by Tenant), subject to commercially reasonable deductibles (Tenant hereby acknowledging that a $100,000 deductible amount is commercially reasonable) during the construction of the Building and other Improvements and Tenant
Improvements, such policy shall be an “All Risk” builder’s risk policy in an amount not less than total replacement cost of the Building and other Improvements and Tenant Improvements under construction (less the cost of such portions
of the Building as are uninsurable under the policy, i.e., site preparation, grading, paving, parking lots, etc., excepting, however, foundations and other undersurface installations subject to collapse or damage by other insured perils), and
including coverage for soft costs including interest expense and loss of rents and (ii) a Commercial General Liability Policy with a combined single limit for bodily injury (including death) or personal injury and property damage of $1,000,000
per occurrence and $2,000,000 general aggregate, subject to commercially reasonable deductibles (Tenant hereby acknowledging that Landlord does not currently use deductibles on commercial general liability policies, but that if Landlord elects to
use deductibles, a $100,000 deductible amount is commercially reasonable) and a Commercial Umbrella or Excess Liability Insurance, written on an “occurrence basis”, including without limitation blanket contractual liability coverage, broad
form property damage, independent contractor’s coverage and personal injury coverage, protecting Landlord with limits of not less than a combined single limit for bodily injury (including death) or personal injury or property damages of
$10,000,000 per occurrence and $10,000,000 general aggregate, and naming Tenant as an additional insured. Within thirty (30) days following receipt of an invoice from Landlord therefor, Tenant shall pay to Landlord, as Additional Rent, the
amount of all premiums paid by Landlord for such insurance policies. Prior to the time such insurance is first required to be carried by Landlord and thereafter, prior to the expiration date of any such policy, Landlord agrees to deliver to Tenant
certificates evidencing such insurance coverage. Said certificate(s) 

  
 30 

 
shall be on a form(s) acceptable to Tenant, in its reasonable judgment, and shall contain an endorsement that the insurer will endeavor to provide thirty (30) days’ written notice to
Tenant before the cancellation of, material change to, lapse or reduction in coverage under such insurance. All such policies shall be written by companies having a rating from Best’s Insurance Reports of not less than A-/IX or a long-term
insurer financial strength rating of A- or better by Standard & Poor’s Rating Services, and reasonably satisfactory to Tenant. All policies shall provide the interest of Tenant shall not be invalidated because of any breach or
violation of any warranties, representations, declarations or conditions contained in the policies. All property insurance policies must contain a waiver of subrogation of claims against Tenant and/or Tenant’s insurer. Notwithstanding anything
to the contrary contained in the Lease, the carrying of insurance by Landlord hereunder shall not modify, reduce, limit or impair Landlord’s obligations and liabilities under this Lease. 

9.3 Notwithstanding anything to the contrary contained herein, from and after the Contraction Effective Date, Tenant shall not be
responsible for purchasing the insurance required under Section 9.1(a)(iv) and Landlord shall thereafter be responsible to purchase such insurance and Tenant’s liability for the cost of the premiums for such insurance and the premiums for
Landlord’s insurance under Section 9.2 (all of which shall be paid by Tenant as Additional Rent) shall be limited to Tenant’s proportionate share thereof, and Tenant shall be credited and/or reimbursed by Landlord with any payment of
insurance premiums for such insurance paid in advance by Tenant for the period after the Contraction Effective Date. 
 10. ALTERATIONS AND
IMPROVEMENTS. 
 10.1 LANDLORD IMPROVEMENTS. Landlord shall construct the Building and Improvements and the Tenant
Improvements and improve the Premises, in accordance with the provisions of this Lease, including the terms and provisions of the Work Letter. All improvements made by Landlord, including without limitation all Improvements and Tenant Improvements,
shall at once become the property of Landlord and shall be surrendered to Landlord upon the expiration or earlier termination of this Lease; provided, Tenant may repair, replace and/or eliminate any Tenant Improvements and other items to be
maintained by Tenant hereunder, but subject to the terms of Section 10.2 below, as applicable. Notwithstanding anything to the contrary contained in this Lease, all of Tenant’s trade fixtures, personal property or communications equipment
and any Generator installed by Tenant in accordance with Section 21.3 shall remain the property of Tenant and shall not be deemed the property of Landlord. Within fifteen (15) business days after the date of Substantial Completion of all
the Building, the other Improvements and all the Tenant Improvements, LLI/IKM, in consultation with and at the direction of Tenant’s Representative and Landlord’s Representative (as those terms are defined in the Work Letter), in
accordance with the Work Letter shall compile the Punch List for the Building and other Improvements and Tenant Improvements, which shall be corrected or completed by Landlord in accordance with the Work Letter. 

10.2 TENANT ALTERATIONS. Except as otherwise set forth herein, Tenant shall not make or allow to be made any alterations, physical
additions or improvements in or to the Premises (collectively, an “Alteration”), without first obtaining the written consent of Landlord, 

  
 31 

 
which consent shall not be unreasonably withheld, delayed or conditioned. Notwithstanding anything to the contrary set forth above or elsewhere in this Lease, Tenant shall be permitted to perform
Permitted Alterations (with a contractor designated by Tenant and approved by Landlord in writing, which approval shall not be unreasonably withheld, delayed or conditioned) to the interior of the Building. The following Alterations are referred to
as “Permitted Alterations”: any Alteration which (a) is non-structural, including, but not limited to, any which are primarily cosmetic in nature; (b) does not cause any violation of and do not require any change in any
certificate of occupancy applicable to the Premises or any portion thereof; (c) does not materially affect the functioning of the mechanical utilities, systems or equipment of the Building or other Improvement; (d) does not exceed $100,000
in any one instance (for purposes of this provision, a series of related alterations shall be aggregated together for purposes of determining whether such $100,000 threshold is exceeded); (e) does not in any way involve or affect the exterior
of the Building; (f) does not in any way involve or affect the structure of the Improvements; (g) does not reduce in any respect the value of the Buildings (other than a de minimis reduction), the other Improvements or the Premises;
(h) is made with due diligence, in a good and workmanlike manner, and in compliance with all Laws; and (i) is promptly and fully paid for by Tenant. Tenant shall give Landlord prior notice of any Permitted Alteration, but the prior written
consent of Landlord to any Permitted Alteration shall not be required. All Alterations made by Tenant (excluding moveable equipment, furniture or trade fixtures of Tenant) shall at once become the property of Landlord and shall be surrendered to
Landlord upon the expiration or earlier termination of this Lease unless Landlord elects by notice to Tenant at the time of granting consent; provided, however, that if Tenant fails to obtain such consent, Landlord may elect by notice to Tenant at
any time thereafter (or, with respect to Permitted Alterations, unless Landlord elects by notice to Tenant within thirty (30) days after Landlord’s receipt of Tenant’s prior notice of the applicable Permitted Alterations, provided,
however, that if such prior notice is not given by Tenant, Landlord may elect by notice to Tenant at any time thereafter) to have Tenant remove such Alteration on or before the expiration or earlier termination of this Lease, and repair any damage
caused thereby in order to restore the Premises to substantially the condition as existed prior to the making of such Alteration, normal wear and tear and casualty damage excepted, and all costs of removal and repair to be borne by Tenant. Tenant
shall be responsible for obtaining, at its cost, all permits required as to any Alteration; Landlord agrees to cooperate with Tenant, at Tenant’s cost, in obtaining all such permits. Tenant shall provide a copy of such permits to Landlord prior
to starting work. Upon completion of any Alteration involving the construction or relocation of walls or partitions, Tenant shall deliver to Landlord a copy of the as-built plans or drawings with respect to such Alterations, as well as, if any,
copies of operation and maintenance manuals for any non-moveable equipment installed in the Premises. Subject to the terms and conditions of the Declaration, Tenant may also perform landscaping and other exterior work not made to the Building
without the consent of Landlord being required. Tenant shall not do or permit to be done any act which results in a lien being filed against the Premises or Property; if a lien so results, Tenant shall cause the same to be removed or bonded over
within thirty (30) business days after written notice to Tenant of the filing thereof. Tenant shall have no authority, express or implied, to create any lien, charge or encumbrance upon the interest of Landlord in the Premises or Property.

  
 32 

 11. CASUALTY. 
 11.1 OPTION TO TERMINATE. If the Building, the Premises or any portion thereof are materially damaged by fire or any other casualty, Landlord will provide to Tenant with reasonable diligence, but
in no event more than sixty (60) days after the occurrence of the fire or other casualty, an estimate from a construction professional (together with Landlord’s agreement thereto) of the time necessary to repair and restore the Premises to
substantially the same condition as existed immediately prior to such casualty (the “Construction Estimate”). If the Construction Estimate states that the Premises cannot be so restored within two hundred seventy (270) days
following the date of such casualty, Tenant may terminate this Lease by providing written notice of its election to do so to Landlord within twenty (20) business days after the date upon which the Construction Estimate is provided to Tenant by
Landlord. If the Lease is so terminated, the termination will be effective as of the date of the casualty (or such later date that Tenant shall cease operations in the Premises), and any Rent paid for any period beyond such date shall be refunded to
Tenant (and/or apportioned, if applicable as a result of use of a portion of the Premises by Tenant after the fire or casualty). If Tenant fails to notify Landlord of its desire to terminate this Lease within such twenty (20) business day
period, Tenant shall be deemed to have waived its right to terminate this Lease under this Section 11.1. 
 If the Premises or any material
portion of the Buildings is destroyed or materially damaged by fire or other casualty at any time during the last twenty four (24) months of the Term, then Landlord and Tenant shall each have the right independent of the other to terminate this
Lease by giving written notice to the other within sixty (60) days after the date of such destruction; provided, if Tenant exercises an option to extend the term of this Lease within thirty (30) days after receipt of Landlord’s notice
of termination, Landlord’s notice of termination will be null and void, but subject to the terms of Section 5.2 hereof regarding the setting of the Market Rate Rent during such Extension Term and the right of Tenant to rescind such
election thereunder. 
 In the event of termination of this Lease pursuant to this Section 11.1, then all Rent shall be apportioned and
paid to the date on which possession is relinquished or the date of such damage, whichever last occurs; in the event this Lease is not terminated hereunder, Landlord shall promptly commence and complete the required repair and restoration. Tenant
shall give prompt notice to Landlord in case of fire or casualty in the Leased Premises. 
 11.2 RESTORATION. If this
Lease is not terminated as provided at Section 11.1 above, then the Premises will, as soon as reasonably possible, be repaired and/or rebuilt by Landlord in good workmanlike manner, so that the restored Premises are completed within the time
period set forth for completion in the Construction Estimate, and such restored Premises are substantially similar to the condition immediately prior to such casualty. Except for actual physical damage to property caused by (a) a default by
Landlord hereunder or (b) the willful misconduct or gross negligence of Landlord, or a Landlord Party, or their respective agents, employees or contractors, Landlord shall have no liability to Tenant for inconvenience, loss of business, or
annoyance arising from any loss by fire or other casualty or by any repair of any portion of the Premises or the Building. Rent shall equitably abate, based on the square footage of the area not suitable for Tenant’s business needs on account
of such damage or destruction, 

  
 33 

 
pending completion of all repair and reconstruction work contemplated under this Section 11.2. In the event of any such damage or destruction, and regardless of whether or not this Lease is
terminated on account thereof, Tenant shall pay to Landlord an amount equal to the deductible under Landlord’s insurance obtained pursuant to Section 9.2 above but in no event more than the commercially reasonable deductible of $100,000
set forth in Section 9.2 above. Landlord shall cause all proceeds of the insurance required of Landlord under Section 9.2 above and the deductible amount paid by Tenant to be made available for the repair and restoration of the Premises;
provided however that so long as Landlord’s insurance deductible is not more than $100,000 and the casualty was not the result of a default by Landlord hereunder or as a result of the willful misconduct or gross negligence of Landlord, or a
Landlord Party, or their respective agents, employees or contractors, notwithstanding anything to the contrary set forth herein, in no event shall Landlord be obligated to expend for such repair/replacement an amount in excess of the actual
insurance proceeds recovered by Landlord, together with the reasonable deductible to be paid to Landlord by Tenant hereunder or assigned to Landlord as a result of such casualty. Landlord’s obligation to restore shall be limited to the
improvements that were in place as of the Commencement Date and any other alterations or improvements made by Landlord, including the Tenant Improvements and any item previously repaired or replaced by Tenant the Qualified Capital Expenses of which
repair or replacement were to be paid in part by Landlord pursuant to Section 8.2(c) above; in no event shall Landlord be obligated to restore any improvements which were installed by Tenant (other than any item previously repaired or replaced
by Tenant the Qualified Capital Expenses of which repair or replacement were to be paid in part by Landlord pursuant to Section 8.2(c) above), unless such improvements were covered by the insurance obtained pursuant to Section 9.2, and
then only to the extent of available insurance proceeds attributable thereto (unless insurance is unavailable as a result of the acts or omission of Landlord, a Landlord Party or their respective agents, employees or contractors). 

If Landlord shall not have restored the Premises within the two hundred seventy (270) day period set forth at Section 11.1
above, Tenant may terminate this Lease, provided that Tenant shall have given Landlord notice of such termination after the expiration of such period and Landlord shall not have completed the restoration within thirty (30) days following the
delivery of such notice, and provided further that Tenant shall not have the right to so terminate this Lease if the damage or destruction is caused by the willful misconduct or negligence of Tenant, or any Tenant Permittee. 

11.3 ABATEMENT OF RENT. In the event of a casualty to the Premises, except as otherwise provided in this Section 11, the Rent
shall abate equitably in proportion to the portion of the entire Premises that is rendered untenantable by reason of fire or other casualty pending, if applicable, the termination of this Lease as a result of such casualty. Notwithstanding the
foregoing, there shall be no abatement of Base Rent by reason of any portion of the Premises being unusable or inaccessible for a period equal to three (3) consecutive days or less. Landlord shall use reasonable discretion as to the extent of
the untenantability of the Premises and of the time required for the repair and rebuilding of the same and no such damage or untenantability shall be deemed either an actual or constructive eviction or result in any abatement of rent, except as
expressly provided in this Section 11. 

  
 34 

 11.4 TENANT’S ACTS. If any casualty occurs as a result of the gross negligence
or the intentional acts of Tenant or Tenant’s Permittees, and the proceeds of insurance which are actually received by Landlord are not sufficient to pay for the repair of all of the damage caused by said casualty, Tenant shall pay to Landlord,
upon demand as Additional Rent, the difference between the cost of repairing the damage and the insurance proceeds actually received by Landlord. 
 11.5 TENANT’S PROPERTY. Except if caused by a default hereunder by Landlord or the gross negligence or intentional wrongful acts or omission of Landlord, its agents, employees or contractors,
Landlord, from and after the Commencement Date, shall not be liable to Tenant or Tenant’s Permittees for loss or damage to merchandise, tenant improvements (including, without limitation, those improvements comprising the Tenant Improvements,
Alterations not otherwise to be repaired by Landlord, fixtures, automobiles, furniture, equipment, computers, files or other personal property (hereinafter collectively “Tenant’s Property”) located at the Premises. Except as
otherwise hereunder to be repaired or restored by Landlord, Tenant shall repair or replace all of Tenant’s Property at Tenant’s sole cost and expense. Tenant acknowledges that it is Tenant’s sole responsibility to obtain adequate
insurance coverage to compensate Tenant for damage to Tenant’s Property. 
 11.6 WAIVER OF SUBROGATION. Anything in
this Lease to the contrary notwithstanding, Landlord and Tenant hereby waive and release each other of and from any and all rights of recovery, claim, action or cause of action, against each other, their partners, agents, officers, directors and
employees, for any loss or damage that may occur to the Premises or any portion thereof, or personal property within the Premises or any portion thereof, which is covered by valid and collectible property insurance in effect at the time of such loss
or damage or would have been covered by the property insurance policies required to be carried by Landlord or Tenant hereunder, regardless of cause or origin, including negligence of Landlord or Tenant and their partners, agents, officers and
employees. Landlord and Tenant acknowledge that the waivers and releases set forth in this section are intended to result in any loss or damage which is covered by property insurance being borne by the insurance carrier of Landlord or Tenant, as the
case may be, or by the party having the insurable interest if such loss is not covered by property insurance and this Lease required such party to maintain property insurance to cover such loss. In furtherance thereof, all property insurance
policies provided pursuant to Sections 9.1 and 9.2 above shall include waiver of subrogation clauses. 
 12. CONDEMNATION. 

12.1 TOTAL CONDEMNATION. In the event that a material portion of the Premises shall be permanently taken or condemned for any
public or quasi-public use or purpose by a competent authority in expropriation proceedings, or by any right of eminent domain, or conveyed to such competent authority in lieu of such taking or condemnation, or the use or occupancy of the Premises
or any portion thereof shall be temporarily so transferred with the expectation of such authority that such temporary transfer of use or occupancy shall continue beyond ninety (90) days or the scheduled expiration date of the Term (any of such
transfers hereinafter called a “Permanent Taking”), then, if such Taking shall involve the entire Premises 

  
 35 

 
or such portion of the Premises as shall prevent in Tenant’s reasonable judgment the reasonable use of a substantial portion of the Premises (any of such takings hereinafter called a
“Total Permanent Taking”), then Tenant may elect to terminate this Lease by Notice to Landlord given not later than ninety (90) days after notice of such Total Permanent Taking. If this Lease shall be so terminated, then Rent
and Tenant’s other obligations under this Lease shall cease as of the time of such Total Permanent Taking or such later date that Tenant shall have surrendered the Premises in the manner required by this Lease. 

12.2 PARTIAL CONDEMNATION. If a Permanent Taking shall involve only a portion of the Premises or otherwise does not constitute a
Total Permanent Taking (any of such takings hereinafter called a “Partial Permanent Taking”), then (i) this Lease shall continue as to that portion of the Premises remaining after such Partial Permanent Taking, (ii) the
Rent and other obligations of Tenant under this Lease shall abate equitably as a result of such Partial Permanent Taking and (iii) Landlord shall promptly restore the Premises including the Tenant Improvements hereunder to the extent feasible
given such Partial Permanent Taking, and in accordance with all Requirements, as nearly as possible to its value, condition, character, utility and useful life that existed immediately prior to such Partial Permanent Taking. If Landlord, subject to
Force Majeure and subject to delays caused by Tenant, does not promptly commence and thereafter diligently pursue the restoration of the Premises as required in this Section 12.2, and substantially complete such restoration no later than
one hundred twenty (120) days after the taking, Tenant may either (i) terminate this Lease at any time thereafter prior to the date such restoration is substantially completed upon not less than thirty (30) days notice to Landlord;
provided, if Landlord completes the restoration within thirty (30) days after Tenant’s notice, subject to Force Majeure and subject to delays caused by Tenant, such termination exercise by Tenant will be deemed null and void and this Lease
shall continue in effect as if such right of termination had not been exercised or (ii) perform such repairs at Landlord’s costs and deduct the cost thereof, together with interest thereon at the Default Rate, from any Rent payable
hereunder. 
 12.3 TEMPORARY TAKING. In the event that, other than as part of a Permanent Taking, the use or occupancy of
the Premises or any portion thereof shall be temporarily taken or condemned (other than a temporary taking constituting a Permanent Taking) for any public or quasi-public use or purpose by a competent authority in expropriation proceedings, or by
any right of eminent domain, or the use or occupancy thereof temporarily transferred to such competent authority in lieu of such taking or condemnation (any of such transfers hereinafter called a “Temporary Taking”), then this Lease
shall continue for the balance of the Term as to that portion of the Premises not subject to such Temporary Taking and, after the cessation of such Temporary Taking, the Lease Term shall again also apply to the portion of the Premises which shall
have been subject to such Temporary Taking. All obligations of Tenant under this Lease, with reference to such portions of the Premises subject to the Temporary Taking shall cease and abate during such Temporary Taking, including but not limited to
Rent which shall be proportionately abated during such Temporary Taking Period. 

  
 36 

 12.4 AWARDS. Landlord shall solely be entitled to claim and receive for its own
benefit any award as a result of a Permanent Taking or payment in lieu thereof, provided that Tenant shall be entitled to claim and receive a separate award or payment in lieu thereof for compensation for loss of, or injury to, the business carried
on in the Premises, Tenant’s relocation expense including the cost of removal of Tenant’s trade fixtures and personal property, and for the unamortized cost of leasehold improvements, and for any other compensation to which Tenant is
entitled under the law. Tenant shall be entitled to receive any award granted as a result of a Temporary Taking (provided that, if an Event of Default shall then exist, Landlord shall be entitled to receive directly from the Taking authority and to
retain the same as security for Tenant’s obligations under this Lease and to apply the same toward any Rent or any other sums which may be owed by Tenant). At such time as such Event of Default shall be cured and no other Events of Default
shall exist, Landlord shall pay over such award, less any portion thereof applied as herein provided, to Tenant. 
 13. ASSIGNMENT AND
SUBLETTING. 
 13.1 LANDLORD’S CONSENT REQUIRED. Except as otherwise permitted hereunder, Tenant shall not
voluntarily or by operation of law assign, transfer, hypothecate, mortgage, sublet, license, or otherwise transfer or encumber all or any part of Tenant’s interest in this Lease or in the Premises (hereinafter collectively a
“Transfer”), without Landlord’s prior written consent, which consent may not be unreasonably withheld or conditioned or delayed. Landlord shall respond to Tenant’s written request for consent hereunder within fifteen
(15) days after Landlord’s receipt of the written request from Tenant. Any attempted Transfer without such consent shall be void and shall constitute a material Event of Default by Tenant pursuant to this Lease. Tenant’s written
request for Landlord’s consent shall include, and Landlord’s fifteen (15) day response period referred to above shall not commence, unless and until Landlord has received from Tenant, all of the following information, to the extent
reasonably available to Tenant: (a) financial statements for the proposed assignee or subtenant for the past three (3) years, prepared in accordance with generally accepted accounting principles; (b) a TRW credit report or similar
report on the proposed assignee or subtenant; (c) a detailed description of the business the assignee or subtenant intends to operate at the Premises; (d) the proposed effective date of the assignment or sublease; (e) a copy of the
proposed sublease or assignment agreement which includes all of the terms and conditions of the proposed assignment or sublease; (f) a detailed description of any ownership or commercial relationship between Tenant and the proposed assignee or
subtenant; and (g) a detailed description of any Alterations the proposed assignee or subtenant desires to make to the Premises; provided, if the items required under subsections (e), (f) and/or (g) are not reasonably available at the
time of such request for consent, Landlord agrees to consider such request without such items and Tenant agrees to provide such items at such later time(s) as such items shall be available to it. If the obligations of the proposed assignee or
subtenant will be guaranteed by any person or entity, Tenant’s written request shall not be considered complete until the information described in (a) or (b) of the previous sentence has been provided with respect to each proposed
guarantor. A “Transfer” shall also include the transfer: (a) if Tenant is a corporation, and Tenant’s stock is not publicly traded over a recognized securities exchange, of more than fifty percent (50%) of the voting stock
of such corporation during the Term (whether or not in one or more transfers) (not including a transfer of voting stock in connection with a public stock offering), or the dissolution, merger or liquidation

  
 37 

 
of the corporation; or (b) if Tenant is a partnership, limited liability company, limited liability partnership or other entity, of more than fifty percent (50%) of the profit and loss
participation in such partnership or entity during the Term (whether or not in one or more transfers) or the dissolution, merger or liquidation of the partnership, limited liability company, limited liability partnership or other entity.
Notwithstanding the foregoing to the contrary, the transfer of stock which is publicly traded on a nationally or internationally recognized stock exchange, whether of Tenant, or any entity controlled directly or indirectly controlling Tenant, or of
any other corporation whose securities are publicly traded on a nationally or internationally recognized securities exchange (including the NASDAQ over-the-counter market), shall not be deemed an assignment and shall not result in an assignment
being caused, regardless of whether “controlling interest” is transferred. Tenant’s sole remedy in the event that Landlord shall wrongfully withhold consent to or disapprove any assignment or sublease shall be to obtain an order by a
court of competent jurisdiction that Landlord grant such consent, and in no event shall Landlord be liable for damages with respect to its granting or withholding consent to any proposed assignment or sublease. 

13.2 STANDARD FOR APPROVAL. Tenant acknowledges and agrees that each requirement, term and condition in this Section 13 is a
reasonable requirement, term or condition, and that it shall be deemed reasonable for Landlord to withhold its consent to a Transfer if any requirement, term or condition of this Section 13 is not complied with or: (a) the Transfer would
cause Landlord to be in violation of its obligations under any other agreement to which Landlord is a party; (b) in Landlord’s reasonable judgment, a proposed assignee is not able financially to pay the rents due under this Lease as and
when they are due and payable; (c) a proposed assignee or subtenant refuses to enter into a written assignment agreement or sublease or other agreement, reasonably satisfactory to Landlord, which provides that it will abide by and assume all of
the terms and conditions of this Lease for the term of any assignment or sublease and containing such other terms and conditions which Landlord may deem necessary in its reasonable and good faith judgment; (d) the use of the Premises by the
proposed assignee or subtenant will not be a use permitted by this Lease; (e) an Event of Default by Tenant then exists, as defined at Section 14 hereof; (f) if requested by Landlord, the assignee or subtenant refuses to sign a
non-disturbance and attornment agreement in favor of Landlord’s lender (containing terms substantially similar in all material respects with the form of non-disturbance and attornment agreement signed by Tenant, if any, with such lender);
(g) Landlord has sued or been sued by the proposed assignee or subtenant or has otherwise been involved in a legal dispute with the proposed assignee or subtenant; or (h) the assignee or subtenant is a governmental or quasi-governmental
entity or an agency, department or instrumentality of a governmental or quasi-governmental agency. 
 13.3 ADDITIONAL TERMS
AND CONDITIONS. The following terms and conditions shall be applicable to any Transfer: 
 (a) Any assignment of this Lease
or sublease of the Premises shall be subject to all of the terms of this Lease, and any such assignee shall be deemed to have assumed for the benefit of Landlord all obligations of Tenant under this Lease which shall first arise from and after such
assignment, provided that: (i) any Event of Default under this Lease that shall continue 

  
 38 

 
after the date of any such assignment, such as a violation of any provision of this Lease relating to use, maintenance, repair, alterations, insurance, condemnation or laws, shall in all events
be assumed and shall be deemed to have been assumed by, such assignee; and (ii) any obligation not so assumed by any such assignee shall nevertheless be the basis of an Event of Default, entitling Landlord to the exercise of all rights and
remedies under this Lease or otherwise available a law or in equity against such assignee as Tenant, including the right to terminate this Lease and cure such Event of Default at the expense of such assignee as Tenant. Landlord agrees, upon request
of Tenant, to provide an estoppel certificate to Tenant and any proposed assignee or subtenant; 
 (b) Unless otherwise released
by Landlord, no assignment of this Lease or subletting of the Leased Premises shall relieve any assignor or sublessor or any prior Tenant from any obligations of Tenant under this Lease, whether such obligations shall have arisen prior to or after
such assignment or subletting; provided however that, to the extent applicable, in the event that the lender under the then existing first lien Fee Mortgage, if any, determines, in its reasonable discretion, that any such assignee maintains a credit
rating that is equal to or stronger than Tenant’s as of the date of such assignment, Tenant shall be relieved of all obligations under this Lease arising following the effective date of such assignment; 

(c) The acceptance of Rent shall not constitute a waiver or estoppel of Landlord’s right to exercise its rights and remedies for the
breach of any of the terms or conditions of this Section 13; 
 (d) The consent by Landlord to any Transfer shall not
constitute a consent to any subsequent Transfer by Tenant or to any subsequent or successive Transfer by any assignee or subtenant; 
 (e) In the event of any Event of Default under this Lease, unless released from liability hereunder, Landlord may proceed directly against Tenant, or anyone else responsible for the performance of this
Lease, including any subtenant or assignee or guarantor thereof, without first exhausting Landlord’s remedies against any other person or entity responsible therefor to Landlord, or any security held by Landlord; 

(f) Landlord’s written consent to any Transfer by Tenant shall not constitute an acknowledgment that no Event of Default then exists
under this Lease, nor shall such consent be deemed a waiver of any then-existing Event of Default; 
 (g) The discovery of the
fact that any financial statement relied upon by Landlord in giving its consent to an assignment or subletting was materially false (with the knowledge of Tenant), shall, at Landlord’s election, render Landlord’s consent null and void;

 (h) Landlord shall not be liable under this Lease or under any sublease to any subtenant; and 

  
 39 

 (i) No assignment or sublease may be modified or amended in any material respect without
Landlord’s prior written consent; 
 13.4 ADDITIONAL TERMS AND CONDITIONS APPLICABLE TO SUBLETTING. The following
terms and conditions shall apply to any subletting by Tenant of all or any part of the Premises and shall be deemed included in all subleases under this Lease whether or not expressly incorporated therein: 

(a) Tenant hereby absolutely and unconditionally assigns and transfers to Landlord all of Tenant’s interest in all rentals and
income arising from any sublease entered into by Tenant, and Landlord may collect such rent and income and apply same toward Tenant’s obligations under this Lease; provided, however, that until an Event of Default shall occur in the performance
of Tenant’s obligations under this Lease, Tenant may receive, collect and enjoy the rents accruing under such sublease. Landlord shall not, by reason of this or any other assignment of such rents to Landlord nor by reason of the collection of
the rents from a subtenant, be deemed to have assumed or recognized any sublease or to be liable to the subtenant for any failure of Tenant to perform and comply with any of Tenant’s obligations to such subtenant under such sublease, including,
but not limited to, Tenant’s obligation to return any security deposit. Tenant hereby irrevocably authorizes and directs any such subtenant, upon receipt of a written notice from Landlord stating that an Event of Default exists in the
performance of Tenant’s obligations under this Lease, to pay to Landlord the rents due as they become due under the sublease. Tenant agrees that such subtenant shall have the right to rely upon any such statement and request from Landlord, and
that such subtenant shall pay such rents to Landlord without any obligation or right to inquire as to whether such Event of Default exists and notwithstanding any notice or claim from Tenant to the contrary. Nothing herein, however, releases
Landlord from any liability to Tenant arising from an improper exercise of the rights granted Landlord hereunder. 
 (b) In the
Event of Default by Tenant in the performance of its obligations under this Lease and the termination of this Lease as a result of such Event of Default, Landlord, at its option and without any obligation to do so, may thereafter require any
subtenant to attorn to Landlord, in which event Landlord shall undertake the obligations of Tenant under such sublease from the time of the exercise of said option to the termination of such sublease; provided, however, Landlord shall not be liable
for any prepaid rents or security deposit paid by such subtenant to Tenant or for any other prior Events of Defaults of Tenant under such sublease unless and to extent delivered to Landlord by Tenant. 

13.5 LANDLORD’S EXPENSES. In the event Tenant shall assign this Lease or sublet the Premises or request the consent of
Landlord to any Transfer, then Tenant shall reimburse Landlord for all of Landlord’s reasonable costs and expenses incurred in connection therewith, including reasonable out-of-pocket attorneys’ fees and costs, not to exceed Five Thousand
Dollars ($5,000.00). 

  
 40 

 13.6 PERMITTED TRANSFERS. Notwithstanding anything to the contrary contained in this
Lease, Tenant shall be entitled to assign this Lease or sublease all or a portion of the Premises or make any other Transfer, without Landlord’s consent and without the requirement of Tenant to pay Landlord’s expenses under
Section 13.5 above, to: 
 (i) Any other corporation or other entity (each, an “Affiliate”) which is controlled,
directly or indirectly, by or under common control with, Tenant; or 
 (ii) if not otherwise covered by the foregoing clause
(i), to any successor to Tenant, or any direct or indirect parent, subsidiary or other Affiliate of Tenant, by merger, consolidation, joint venture or other reorganization of ownership; 

(iii) an unrelated corporation or entity (A) that acquires all or substantially all of Tenant’s assets, and (B) either
(x) has a Net Worth immediately following such Transfer that is at least equal to the Net Worth (immediately prior to such Transfer) of Tenant, or (y) has a long-term issue credit rating, immediately upon the occurrence of the Transfer, of
BBB- or better according to Standard & Poors, and such Transfer is not entered into as a subterfuge to avoid the restrictions relating to assignments set forth in this Lease or as part of a stepped transaction that has the effect of
avoiding the restrictions relating to assignments set forth in this Lease; or 
 (iv) in addition to the above (i) through
(iii), a sublease or other right to occupy of up to an aggregate of thirty-three and 1/3 percent (33-1/3%) of the Premises, to an entity or entities with whom Tenant has an ongoing business relationship with or without any written agreement, letter
agreement, license agreement or sublease agreement. 
 Each such transaction described in the foregoing clauses (i) through
(iv) and in the grammatical paragraph below (each such transaction, a “Permitted Transfer”, and each such party, a “Permitted Transferee”) shall not be deemed a Transfer, and with respect to each such Permitted Transfer:
(A) Tenant shall notify Landlord of such transaction within 30 days after such occurrence, and (B) except for Permitted Transfers under subsection (iv) above, any such Permitted Transferee shall assume all of Tenant’s obligations
hereunder. 
 13.7 EXCESS RENTALS. One-half (1/2) of any sums or other economic consideration, whether direct or
indirect, received by Tenant as a result of any subletting or assignment authorized pursuant to this Section 13 (except rental or other payments received which are attributable to the amortization of the cost of leasehold improvements, other
than building standard tenant improvements, made to the sublet portion of the Premises by Tenant for subtenant), whether denominated rentals under the sublease or assignment or otherwise, which exceed, in the aggregate, the total sums which Tenant
is obligated to pay Landlord under this Lease (prorated to reflect obligations allocable to that portion of the Premises subject to such sublease or assignment) shall be payable to Landlord as Additional Rent under the terms of this Lease, without
affecting or reducing any other obligation of Tenant hereunder. For the purposes of this Section 13.7, Landlord shall not claim or be entitled to any portion of the consideration paid to Tenant as a part of a Permitted Transfer,
including, but not limited to, any consideration paid for a sale of Tenant’s assets or a controlling interest in or to Tenant (i.e. a sale of shares in Tenant). 

  
 41 

 14. DEFAULT; REMEDIES. 
 14.1 DEFAULT BY TENANT. Landlord and Tenant hereby agree that the occurrence of any one or more of the following events shall, after the expiration of any applicable notice and grace period without
correction thereof, be deemed an “Event of Default” by Tenant under this Lease, and that said Event of Default shall give Landlord the right to exercise its remedies as described at Section 14.2 below. 

(a) Tenant’s failure to make any payment of Base Rent or any other payment of Additional Rent required to be made by Tenant to
Landlord hereunder, as and when due, where such failure shall continue for a period of five (5) days after written notice thereof from Landlord to Tenant; provided, however, that if Landlord shall have given such notice twice in the then
immediately preceding twelve (12)-month period, then no notice shall be required pursuant to this Section 14.1(a); 
 (b)
The failure by Tenant to observe or perform any of the covenants, conditions or provisions of this Lease to be observed or performed by Tenant (other than those referenced at Section 14.1(a) above), where such failure shall continue for a
period of fifteen (15) business days after written notice thereof from Landlord to Tenant; provided, however, that if such failure is of a type that is not curable by Tenant within said fifteen (15) business days after notice thereof, then
such fifteen (15) business day period shall be extended for such additional period that may be reasonably required to effect such cure so long as Tenant, promptly after such notice, shall commence such cure and continuously and diligently
proceed to cure such failure; for purposes hereof a “business day” is any day except a Saturday, Sunday or legal holiday in the United States. 
 (c)(i) The making by Tenant of any general arrangement or general assignment for the benefit of creditors; (ii) Tenant becoming a “debtor” as defined in 11 U.S.C. 101 or any successor
statute thereto (unless, in the case of a petition filed against Tenant, the same is dismissed within sixty (60) days); (iii) the appointment of a trustee or receiver to take possession of substantially all of Tenant’s assets located
at the Premises or of Tenant’s interest in this Lease, where possession is not restored to Tenant within sixty (60) days; (iv) the attachment, execution or other judicial seizure of substantially all of Tenant’s assets located at
the Premises or of Tenant’s interest in this Lease, where such seizure is not discharged within sixty (60) days; or (v) the insolvency of Tenant. In the event that any provision of this Section 14.1(c) is unenforceable under
applicable law, such provision shall be of no force or effect; and/or 
 (d) If Tenant is a corporation, partnership, limited
liability company or similar entity, the voluntary dissolution or liquidation of Tenant, except in connection with a Permitted Transfer hereunder. 
 14.2 REMEDIES. 
 (a) In the event of any Event of Default by Tenant as set forth
at Section 14.1 above, at any time thereafter and so long as the Event of Default is continuing, with or without 

  
 42 

 
notice or demand (other than the notices expressly set forth in Section 14.1), and without limiting Landlord in the exercise of any right or remedy which Landlord may have by reason of such
Event of Default: 
 (i) Landlord may perform for the account of Tenant any such Event of Default of Tenant and recover as
Additional Rent any reasonable expenditure reasonably made by Landlord to cure such Event of Default, together with interest thereon at the Default Rate from the date of such expenditure; 

(ii) Landlord may accelerate all Base Rent due for the balance of the Term of this Lease, and declare the then present value of the same
(based on a factor equal to six percent (6%) per annum) to be immediately due and payable; provided, nothing herein shall limit the right of Tenant to terminate the Lease and/or contract is Premises pursuant to the terms of Sections 3.4 and 2.5
of this Lease, whether before or after an Event of Default; 
 (iii) Landlord, at its option, may serve notice upon Tenant that
this Lease and the then unexpired Term shall cease and expire and become absolutely void on the date specified in such notice, to be not less than five (5) days after the date of such notice without any right on the part of the Tenant to save
the forfeiture by payment of any sum due or by the performance of any term, provision, covenant, agreement or condition broken; and thereupon, at the expiration of the time limit in such notice, this Lease and the Term hereof, as well as the right,
title and interest of the Tenant hereunder, shall wholly cease and expire and become void in the same manner and with the same force and effect (except as to Tenant’s liability) as if the date fixed in such notice were the date herein granted
for expiration of the Term of this Lease. Thereupon, Tenant shall immediately quit and surrender to Landlord the Premises, and Landlord may enter into and repossess the Premises by summary proceedings, detainer, ejectment or otherwise and remove all
occupants thereof and, at Landlord’s option, any property thereon without being liable to indictment, prosecution or damages therefor. Except as otherwise required by applicable law or the terms of this Lease, no such expiration or termination
of this Lease shall relieve Tenant of its liability and obligations under this Lease, whether or not the Premises shall be relet; 
 (iv) Subject to Section 14.2(e) hereof, Landlord may re-enter and repossess the Premises and any part thereof and attempt in its own name, as agent for Tenant if this Lease shall not be
terminated, or in its own behalf if this Lease shall be terminated, to relet all or any part of such Premises for and upon such terms and to such person, firms or corporations and for such period or periods as Landlord, in its sole discretion, shall
determine, including any period beyond the termination of this Lease; and subject to Landlord’s obligation hereunder to mitigate damage pursuant to Section 14.2(e), Landlord shall not be required to accept any lessee offered by Tenant or
observe any instruction given by Tenant about such reletting or to the mitigation of damages. The words “reenter”, “reentry” and “reentered” as used in this Lease are not restricted to their technical legal meanings.
For the purpose of such re-letting, Landlord may make repairs, changes, alterations or additions in or to the Premises to the extent deemed by Landlord, in its reasonable judgment, necessary to place the Premises in such condition as is required
pursuant to Section 16.1 hereof, and the reasonable cost of such repairs, 

  
 43 

 
changes, alterations or additions shall be charged to and be payable by Tenant as Additional Rent hereunder, as well as any reasonable brokerage and legal fees expended by Landlord in connection
with this Section 14.2(a)(iv); and any sums collected by Landlord from any new lessee obtained on account of the Tenant shall be credited against the balance of the Rent due from Tenant hereunder as aforesaid. Tenant shall pay to Landlord
monthly, on the days when the Rent would have been payable under this Lease, the amount due hereunder less the amount obtained by Landlord from such new lessee, or at Landlord’s option, Landlord may elect to accelerate the amount due under this
Lease pursuant to Section 14.2(a)(ii) and declare said amounts immediately due and payable upon demand but discounted to the present value thereof in accordance with the terms of Section 14.2(a)(ii) above; 

(v) Landlord may collect sublease rents (or appoint a receiver to collect such rent) and otherwise perform Tenant’s obligations at
the Premises, it being agreed, however, that the appointment of a receiver for Tenant shall not constitute an election by Landlord to terminate this Lease; 
 (vi) Landlord may pursue any other remedy, at law or in equity, now or hereafter available to Landlord under the laws or judicial decisions of the Commonwealth of Pennsylvania; and 

(vii) Tenant shall pay all of Landlord’s reasonable costs and expenses, including without limitation all reasonable attorneys’
fees and expenses and court costs, incurred in connection with any Event of Default, including any reasonable costs of enforcement. 
 (b) In the event of any termination of this Lease by Landlord following any Event of Default set forth in Section 14.1 hereof or under any eviction or other proceeding or action or any provision of
law, or in the event that Landlord shall re-enter the Premises under the provisions of this Section 14.2, Tenant shall pay to Landlord all items of Base Rent and Additional Rent required to be paid by Tenant hereunder up to the time of such
termination of this Lease, or of such recovery of possession of the Premises by Landlord, as the case may be, and thereafter shall pay to Landlord as damages for loss of its bargain, and not as a penalty, at the election of Landlord, either:

 (i) a sum which at the time of such termination of this Lease or at the time of any such reentry by Landlord, as the case
may be, represents the then value of the excess, if any, of: (A) the aggregate of the installments of Base Rent which would have been payable hereunder by Tenant, had this Lease not so terminated or had Landlord not reentered the Premises, for
the period commencing with such earlier termination of this Lease or the date of any such reentry, as the case may be, and ending with the date set forth for the expiration of the then remaining Term of this Lease (including only the Initial Term
and such Extension Terms as may have then been exercised by Tenant, but excluding to the extent the option to terminate is still available to Tenant, any rental for the period after the date at which Tenant may terminate this Lease pursuant to
Section 3.4 above, over (B) the aggregate rental value of the Premises (inclusive the items set forth in the definition of Market Rate) for the same period, provided that in no event shall the aggregate rental value of the Premises for
such period be deemed to exceed 

  
 44 

 
the sum of the Base Rent for such period (the amounts of each of clauses (A) and (B) being first discounted to present value at an annual rate of six (6%) percent, plus, if and to
the extent the Termination Option has not expired, the Termination Fee that would otherwise be payable (and has not yet been paid) following exercise of such Termination Option but such sum being discounted to present value to the Termination
Effective Date at an annual rate of six percent (6%) per annum; or 
 (ii) subject to Section 14.2(e) hereof, sums
equal to the aggregate of the installments of Base Rent which would have been payable by Tenant had this Lease not so terminated, or had Landlord not so reentered the Premises, payable upon the due dates therefor specified herein following such
termination or such reentry and until the date set forth for the expiration of the then remaining Term of this Lease (including only the Initial Term and such Extension Terms as may have then been exercised by Tenant, but excluding to the extent the
option to terminate is still available to Tenant, any rental for the period after the date at which Tenant may terminate this Lease pursuant to Section 3.4 above, plus, if and to the extent the Termination Option has not expired, the
Termination Fee that would otherwise be payable (and has not yet been paid) following exercise of such Termination Option but such sum being discounted to present value to the Termination Effective Date at an annual rate of six percent (6%) per
annum); provided, however, that if Landlord shall relet the Premises during said period, then Landlord shall credit Tenant with the net rents received by Landlord from such reletting, such net rents to be determined by first deducting from the gross
rents as and when received by Landlord from such reletting the reasonable expenses incurred or paid by Landlord in terminating this Lease and of reentering the Premises and of securing possession thereof, including reasonable attorneys’ fees
and costs of removal and storage of Tenant’s property, as well as the reasonable expenses of reletting, including repairing, restoring and improving the Premises for new tenants, brokers’ commissions, advertising costs, reasonable
attorneys’ fees, and all other similar or dissimilar expenses chargeable against the Premises and the rental therefrom in connection with such reletting, it being understood that such reletting may be for a period equal to or shorter or longer
than the remaining Term of this Lease; provided further, that (A) in no event shall Tenant be entitled to receive any excess of such net rents over the sums payable by Tenant to Landlord hereunder, (B) in no event shall Tenant be entitled
in any suit for the collection of damages pursuant to this subsection (ii) to a credit in respect of any net rents from a reletting except to the extent that such net rents are actually received by Landlord prior to the commencement of such
suit, and (C) if the Premises or any part thereof should be relet in combination with other space, then proper apportionment on a square foot area basis shall be made of the rent received from such reletting and of the expenses of reletting, or
if relet for a period longer than the remaining Term of this Lease, the expenses of reletting shall be apportioned based on the respective periods. 
 (c) No remedy or election hereunder shall be deemed exclusive, but shall, wherever possible, be cumulative with all other remedies at law or in equity. The expiration or termination of this Lease and/or
the termination of Tenant’s right to possession of the Premises shall not relieve Tenant of liability under any indemnity provisions of this Lease as to matters occurring or accruing during the Term of the Lease or by reason of Tenant’s
occupancy of the Premises. 

  
 45 

 (d) If Tenant abandons or vacates the Premises and subsequently fails to pay Rent as and
when due, Landlord may re-enter the Premises, and such re-entry shall not be deemed to constitute Landlord’s election to accept a surrender of the Premises or to otherwise relieve Tenant from liability for its Event of Default under this Lease.
No surrender of the Premises shall be effective against Landlord unless Landlord has entered into a written agreement with Tenant in which Landlord expressly agrees to: (i) accept a surrender of the Premises; and (ii) relieve Tenant of
liability under the Lease. The delivery by Tenant to Landlord of possession of the Premises shall not constitute the termination of the Lease or the surrender of the Premises. 
 (e) If Landlord terminates this Lease or Tenant’s right to possession, or elects to accelerates the Rent , Landlord shall have a duty to mitigate Landlord’s damages; provided, however, that:
(i) Landlord shall be required only to use commercially reasonable efforts to mitigate and otherwise to relet the Premises, in recognition that the value of the Building depends on the use being made thereof, rental rates and terms of leases
therein, Landlord’s rejection of a prospective replacement tenant based on such tenant’s proposed use of the Premises, an offer of rentals below the rates provided in this Lease or containing terms less favorable than those contained
herein, shall not give rise to a claim by Tenant that Landlord failed to mitigate Landlord’s damages; and (ii) Tenant agrees that Landlord’s damages shall not have been mitigated by virtue of Landlord any leasing of any property of
Landlord or any affiliate of Landlord other than the Premises, Tenant hereby acknowledging that Landlord and such affiliate shall be entitled to lease any other property without any obligation first to attempt to relet the Premises and without any
right of Tenant to a defense, right of set-off, reduction in damages or any other relief based on any lease of any other property. 
 (f) In the event of any termination of this Lease by Landlord following any Event of Default, Tenant’s obligations under the Lease for the payment of Base Rent and Additional Rent shall cease and
determine as of the date of such termination, provided that Tenant shall nevertheless remain liable, notwithstanding such termination, for the amounts payable to Landlord pursuant to this Section 14.2. Tenant acknowledges that Landlord’s
pecuniary loss for breach of this Lease by Tenant is not susceptible of precise ascertainment, and that the measure of damages set forth in this Lease is a reasonable approximation of Landlord’s actual damages, and not a penalty. 

14.3 LATE CHARGES. Tenant hereby acknowledges that late payment by Tenant to Landlord of Rent or other sums due hereunder will
cause Landlord to incur costs not contemplated by this Lease, the exact amount of which will be extremely difficult to ascertain. Such costs include, but are not limited to, processing and accounting charges and late charges which may be imposed on
Landlord by the terms of any Fee Mortgage encumbering the Premises. Accordingly, if any installment of Rent or any other sum due from Tenant shall not be received by Landlord within ten (10) days after Landlord gives Tenant written notice that
such amount shall be due, then, without any requirement for notice or demand to Tenant, Tenant shall 

  
 46 

 
immediately pay to Landlord a late charge equal to five percent (5%) of such overdue amount, but in no event more than the amount required to reimburse the Landlord for any late charges or
interest paid to its lender which directly results from the delinquent payment by Tenant of any such sums payable hereunder. The parties hereby agree that such late charge represents a fair and reasonable estimate of the costs Landlord will incur by
reason of late payment by Tenant. Acceptance of such late charge by Landlord shall in no event constitute a waiver of Tenant’s Event of Default with respect to such overdue amount, nor prevent Landlord from exercising any of the other rights
and remedies granted hereunder, including the assessment of interest under Section 14.5 below. 
 14.4 INTEREST ON PAST
DUE OBLIGATIONS. Any Rent or other sum payable under this Lease and which is not paid within ten (l 0) days after written notice that the same is then due and payable shall bear interest at the rate per annum equal to the lesser of (a) the
Default Rate, or (b) the highest rate permitted by law. Such rate of interest shall apply irrespective of whether judgment may have been entered therefore, and payment of such interest shall not excuse or cure any Event of Default by Tenant
under this Lease; provided, interest shall not be payable on late charges incurred by Tenant nor on amounts upon which late charges are paid by Tenant. 
 14.5 DEFAULT BY LANDLORD; TENANT’S REMEDIES. A “Landlord Default” shall be deemed to have occurred: (i) if Landlord shall fail to pay, when due, any sums due Tenant from
Landlord hereunder (including any interest due hereunder) and such failure is not cured within fifteen (15) business days after written notice to Landlord and to the holder of any first lien Fee Mortgage encumbering the Premises whose name and
address shall have been theretofor furnished to Tenant in writing (“Mortgagee”) from Tenant; or (ii) if Landlord shall fail to perform any of the other covenants, terms or provisions of this Lease and such failure is not cured within
thirty (30) days after written notice thereof to Landlord and Mortgagee from Tenant; provided, however, that no Landlord Default shall occur if the failure is susceptible to cure but is not susceptible to cure within thirty (30) days so
tong as Landlord promptly commences the cure within such thirty (30) day period and diligently and continuously pursues it to completion as soon as reasonably possible. Notwithstanding anything to the contrary contained in this
Section 14.5, and except as otherwise expressly provided at Section 3.2(c) above, no notice or opportunity to cure shall be required in connection with a default by Landlord in failing to substantially complete construction of the Building
and other Improvements and Tenant Improvements by any of the respective Target Completion Dates, such failure being a Landlord Default immediately upon such default occurring. Upon a Landlord Default hereunder, Tenant may perform the failed
obligation of Landlord and deduct any reasonable expense associated with such performance from the Rent or other charges next becoming due until Tenant is reimbursed in full (or, in the event that such reimbursement obligation has not been satisfied
prior to the expiration of the Term, Tenant may institute an action for damages relating to any such deficiency). Except to the extent otherwise expressly permitted under the Lease, in no event shall Tenant have the right to terminate this Lease as
a result of a Landlord Default, and Tenant’s sole and exclusive remedies in the event of a default by Landlord under this Lease shall be as expressly set forth in the immediately-preceding sentence or otherwise in this Lease and/or an
injunction. 

  
 47 

 14.6 WAIVER OF CERTAIN DAMAGES. Notwithstanding anything to the contrary contained
herein, Landlord and Tenant hereby waive each’s respective right to recover consequential damages (including, but not limited to, lost profits) or punitive damages arising out of a default by the other party hereunder. 

15. DISCHARGE OF LIENS. 

15.1 DISCHARGE OF LIENS. Tenant shall not create, permit or suffer to exist, and shall discharge any lien, encumbrance or charge
(other than the lien of any governmental authority for taxes or assessments not then due and payable) upon the Premises or any portion thereof or interest therein existing as a result of: (a) Tenant’s noncompliance with any of the terms of
this Lease; (b) any Alterations or improvements to the Premises made by Tenant; or (c) any wrongful acts or omissions of Tenant or any of Tenant’s Permittees (each a “Lien”). If any Lien shall at any time exist, then
Tenant shall cause such Lien to be discharged, by bond or otherwise, within thirty (30) days after notice of the creation of such Lien. If Tenant shall so fail to discharge such Lien, then such failure shall constitute an Event of Default and,
in addition to any other right or remedy Landlord may have under this Lease or at law or in equity, Landlord may take such actions as Landlord may elect, including the payment of any sums and the performance of any obligations claimed to be secured
by such Lien. Any amount so reasonably paid by Landlord and any reasonable costs or expenses reasonably incurred by Landlord in connection with such Lien or the payment or performance of any sums or other obligations claimed to be secured thereby
shall constitute Additional Rent and shall be paid by Tenant on demand. 
 15.2 NO CONSENT BY LANDLORD. Nothing in this
Lease and no consent now or hereafter given by Landlord to any action taken by Tenant shall be construed as a consent of or request by Landlord, express or implied, to any contractor, subcontractor or other party for the performance of any work
requested by Tenant or the provision of any material or equipment to Tenant which would form the basis of a mechanic’s, materialman’s or other lien against Landlord’s interest in the Premises or any portion thereof. 

16. SURRENDER OF PREMISES. 
 16.1 SURRENDER. On or before the expiration or earlier termination of the Term, Tenant shall deliver and surrender exclusive possession of the Premises to Landlord, clear of all subleases,
concessions, licenses and other occupancies. Tenant shall surrender the Premises (including, but not limited to, all doors, windows, floors and floor coverings, skylights, heating and air conditioning systems, dock boards, truck doors, dock bumpers,
plumbing work and fixtures, electrical systems, lighting facilities, sprinkler systems, fire detection systems and other portions of the Premises to be maintained by Tenant under the terms of this Lease (collectively the “Elements of the
Premises”) to Landlord in the same condition as received or as the same may be altered, repaired or replaced by Tenant in accordance with the terms of this Lease, as 

  
 48 

 
applicable, ordinary wear and tear and casualty damage excepted, Alterations made by Tenant and not required to be removed in accordance with the terms hereof excepted, and clean and free of
debris and Tenant’s personal property, trade fixtures and equipment. If Tenant fails to remove any Alterations, trade fixtures, equipment or other property required to be removed by the terms of this Lease, in addition to any other remedies
available to Landlord under this Lease or applicable law, Landlord may remove any such property from the Premises and store the same elsewhere at the expense and risk of Tenant. Tenant shall, at Tenant’s sole cost and expense, repair any damage
to the Premises occasioned by the removal of Tenant’s Alterations, trade fixtures, furnishings and equipment required to be removed by the terms of this Lease. Damage to or deterioration of any Element of the Premises or any other item Tenant
is required to repair or maintain upon Premises shall not be deemed ordinary wear and tear if the same could have been prevented by good maintenance practices. 
 16.2 HOLDING OVER. If Tenant shall not surrender the Premises when required pursuant to Section 16.1 of this Lease, then, at Landlord’s option elected in writing by Landlord at any time,
Tenant shall be deemed to be a month-to-month tenant thereof, and in the absence of such written election by Landlord, Tenant shall be a tenant thereof at the sufferance of Landlord. During any such tenancy, Tenant shall be bound by all the terms
and conditions of this Lease, and shall pay to Landlord, in addition to all Additional Rent, a Base Rent per square foot of rentable area of the Leased Premises not so surrendered in the amount of 150% the Base Rent per square foot of rentable area
that shall have been in effect for the month of the Lease Term immediately prior to the time required for such surrender, the parties agreeing that such sum shall be deemed a reasonable sum for such tenancy. Except as set forth in Section 16.3
and hereafter, nothing herein shall limit the right of Landlord to damages for periods after the expiration of any tenancy created by this Lease. Tenant shall indemnify, defend and hold Landlord harmless from and against any and all damages,
expenses, costs, losses or liabilities arising from any delay by Tenant in timely surrendering the Premises in accordance with the provisions of this Lease, including, without limitation, any damages, expenses, costs, losses or liabilities arising
from any claim against Landlord made by any succeeding tenant or prospective tenant founded on or resulting from such delay and losses and damages suffered by Landlord due to lost opportunities to lease any portion of the Premises to any such
succeeding tenant or prospective tenant, together with, in each case, actual attorneys’ fees and costs. 
 16.3
TENANT’S HOLDOVER OPTION. Notwithstanding anything to the contrary set forth at Section 16.2 above, Tenant shall have the option to occupy the Premises for a period of up to three (3) successive calendar months following the
expiration of the Term, without incurring any penalties or liabilities in accordance with Section 16.2 above, provided that all of the following conditions have been satisfied: (i) Tenant shall provide Landlord with written notice of its
intent to exercise its option to so hold over at least one hundred eighty (180) days prior to the expiration of the Term, which notice shall state the duration of the requested hold over period; provided, Tenant may at any time during such
requested hold over period early terminate such hold over upon not less than thirty (30) days prior written notice to Landlord, in which event such hold over period and the Lease shall terminate upon such earlier termination date; (ii) the
Term must expire at the time of its originally-scheduled expiration date pursuant to 

  
 49 

 
this Lease, and must not be terminated in advance of such date for any reason whatsoever (the exercise of the Contraction Option set forth in. Section 2.5 above shall not be deemed to be a
termination under this Subsection (ii)); (iii) all terms and conditions of this Lease, including without limitation the calculation of all Rent, shall continue in full force and effect during said holdover period; (iv) the expiration date
of the requested hold over period (not to exceed three (3) calendar months) shall (except for an early termination pursuant to Subsection (i) above) be conclusively deemed to be the expiration of the Lease Term for all purposes, whereupon
the provisions of Section 16.2 above shall apply in all respects; and (v) there must exist no Event of Default by Tenant, either at the time of Tenant’s notification of its intent to exercise its Holdover Option, or as of the
originally-scheduled expiration of the Term. 
 17. INDEMNITY. 
 17.1 TENANT’S INDEMNIFICATION OBLIGATIONS. Tenant hereby agrees to indemnify, defend and hold harmless Landlord and all Landlord Parties (said persons and entities are, for purposes of this
Section 17, collectively referred to as the “Indemnified Parties”) from and against any and all liability, loss, cost, damage, claims, loss of rents, liens, judgments, penalties, fines, settlement costs, investigation costs,
cost of consultants and experts, attorneys fees, court costs and other legal expenses (hereinafter collectively referred to as “Damages”) arising out of or related to an Indemnified Matter (as defined below). For purposes of this
Section 17, an “Indemnified Matter” shall mean any matter for which one or more of the Indemnified Parties incurs liability or Damages if the liability or Damages arise out of or involve, directly or indirectly:
(a) Tenant’s or its employees’, agents’ or contractors’, or any other of Tenant’s Permittees’ (all said persons are sometimes collectively herein called “Tenant Parties”) operation, business, use,
maintenance or occupancy of the Premises; (b) any wrongful act, omission or neglect of a Tenant Party, (c) Tenant’s failure to perform any obligations under the Lease; (d) any breach by Tenant of its environmental representations
set forth in Section 4.3(a) above; (e) any accident, injury or death of person or loss or damage to property occurring on or about the Premises caused by a Tenant Party; or (f) any other matters for which Tenant has agreed to
indemnify Landlord pursuant to any other provision of this Lease. Tenant’s obligations hereunder shall include, but shall not be limited to: (x) compensating the Indemnified Parties for Damages arising out of Indemnified Matters within
thirty (30) days after written demand from an Indemnified Party; and (y) providing a defense, with counsel reasonably satisfactory to the Indemnified Party, at Tenant’s sole expense, within ten (10) days after written demand from
the Indemnified Party, of any claims, action or proceeding arising out of or relating to an Indemnified Matter whether or not litigated or reduced to judgment and whether or not well founded. If Tenant is obligated to compensate an Indemnified Party
for Damages arising out of an Indemnified Matter, Landlord shall have the immediate and unconditional right, but not the obligation, without notice or demand to Tenant, to pay the damages, and Tenant shall, upon thirty (30) days’ advance
written notice from Landlord, reimburse Landlord for the reasonable costs incurred by Landlord, The Landlord Indemnified Parties need not first pay any Damages to be indemnified hereunder. The indemnification obligations set forth pursuant to this
Section 17 are intended to apply to the fullest extent permitted by applicable law. Tenant’s obligations under this section shall survive the expiration or termination of this Lease unless specifically waived in writing by Landlord after
said expiration or termination. Notwithstanding the foregoing, Tenant shall not be obligated to indemnify Landlord from Damages arising out of Landlord’s or any Landlord Parties’ negligence, willful misconduct or breach of this Lease.

  
 50 

 17.2 LANDLORD ‘S INDEMNIFICATION OBLIGATIONS. Landlord hereby agrees to
indemnify, defend and hold harmless Tenant and its employees, trustees, agents, contractors and lenders (said persons and entities are hereinafter collectively referred to as the “Tenant Indemnified Parties”) from and against any
and all liability, loss, cost, damage, claims, loss of rents, liens, judgments, penalties, fines, settlement costs, investigation costs, cost of consultants and experts, attorneys fees, court costs and other legal expenses, effects of environmental
contamination, cost of environmental testing, removal, remediation and/or abatement of Hazardous Maters (as defined below), insurance policy deductibles and other expenses (hereinafter collectively referred to as “Damages”) arising
out of or related to a Landlord Indemnified Matter (as defined below), For purposes of this Section 17, a “Landlord Indemnified Matter” shall mean any matter for which one or more of the Tenant Indemnified Parties incurs
liability or Damages if the liability or Damages arise out of or involve, directly or indirectly, (a) Landlord’s or its employees’, agents’, contractors’, invitees’, sublessees’ or assignees’ (all of said
persons or entities are sometimes herein collectively referred to as “Landlord Parties” and individually, “Landlord Party”) operation, business, use, maintenance or occupancy of the Premises, the Building or the
Land, (b) any act, omission or neglect of a Landlord Party, (c) Landlord’s failure to perform any of its obligations under the Lease, (d) the breach by Landlord of any of its environmental representations or covenants under this
Lease, (e) any accident, injury or death of person or loss or damage to property occurring on or about the Premises, the Building or the Land caused by a Landlord Party or (f) any other matters for which Landlord has agreed to indemnify
Tenant pursuant to any other provision of this Lease. Landlord’s obligations hereunder shall include, but shall not be limited to: (i) compensating the Tenant Indemnified Parties for Damages arising out of Landlord Indemnified Matters
within thirty (30) days after written demand from a Tenant Indemnified Party, and (ii) providing a defense, with counsel reasonably satisfactory to the Tenant Indemnified Party, at Landlord’s sole expense, within ten (10) days
after written demand from the Tenant Indemnified Party, of any claims, actions or proceeding arising out of or relating to a Landlord Indemnified Matter whether or not litigated or reduced to judgment and whether or not well founded. If Landlord is
obligated to compensate a Tenant Indemnified Party for Damages arising out of a Landlord Indemnified Matter, Tenant shall have the immediate and unconditional right, but not the obligation, without notice or demand to Landlord, to pay the damages,
and Landlord shall, upon thirty (30) days’ advance written notice from Tenant, reimburse Tenant for the costs incurred by Tenant. The Tenant Indemnified Parties need not first pay any Damages to be indemnified hereunder. This indemnity is
intended to apply to the fullest extent permitted by applicable law. Landlord’s obligations under this Section 17 shall survive the expiration or termination of this Lease unless specifically waived in writing by Tenant after said
expiration or termination. Notwithstanding the foregoing, Landlord shall not be obligated to indemnify Tenant from Damages arising out of Tenant’ negligence, willful misconduct or breach of this Lease. 

  
 51 

 18. WAIVERS. 
 18.1 WAIVER OF LIABILITY. Tenant agrees that all fixtures, equipment, merchandise, inventory and other personal property of Tenant, Tenant’s Permittees, or Tenant’s officers, directors,
managers, agents, shareholders, partners, members, trustees, beneficiaries and all other Persons with interests, directly or indirectly in Tenant, and the respective agents and employees of each of the foregoing (each, a “Releasing
Party”) which may at any time now or in the future be in the Premises shall be maintained there at such Releasing Parties’ sole risk, except to the extent of the cost of damage caused by the negligence or willful misconduct of a
Landlord Party. Except for any obligations and liabilities of the Landlord expressly set forth pursuant to this Lease, including but not limited to warranty obligations of Landlord hereunder, and for the gross negligence or intentional acts or
omissions of a Landlord Party, Landlord shall have no other liability by reason of any damage or injury caused or alleged to have been caused by the condition of the Premises, 
 19. EXONERATION. Neither Landlord nor any Landlord Parties, nor any other party with an interest in Landlord, shall be subject to personal liability for breach of any of the covenants,
representations or warranties of Landlord under this Lease, or for any other acts or omissions, if any, not released pursuant to this Lease, beyond Landlord’s interest in the Premises and the rents, revenues and insurance proceeds therefrom
and/or therefor, and Tenant shall seek recourse with respect thereto solely against such interest of Landlord in the Premises and the rents, revenues and insurance proceeds therefrom and/or therefor for the satisfaction of the remedies of Tenant.
Nothing in this Section 19 shall be construed to authorize Tenant to set off any claim or right of Tenant against Landlord against any Rent or other sum otherwise owed by Tenant under this Lease, and any such right shall be permitted only to
the extent expressly permitted by the other terms of this Lease. The lien of any judgment that may be entered against Landlord with respect to any matter referred to in this Section 19 shall be limited to Landlord’s interest in the
Premises and the rents, revenues and insurance proceeds therefrom and/or therefor. Nothing herein, however, shall release the Landlord Guarantor for liability under the Landlord Guaranty. 

20. SUBORDINATION AND TRANSFER. 
 20.1 SUBORDINATION. Tenant accepts this Lease subject and subordinate to any present or future fee mortgage upon Landlord’s interest in the Premises, as well as any related assignment of
Landlord’s rights under this Lease, including the right to receive Rent hereunder (collectively, “Fee Mortgages”), irrespective of the extent of the indebtedness or obligations secured by such Fee Mortgages, provided that such
Fee Mortgagees shall not disturb Tenant’s rights under this Lease in the absence of an Event of Default. Subject to Tenant’s receipt of a fully executed SNDA (as defined below), the subordination described in the preceding sentence shall
be self-operative; provided, however, that Tenant shall execute, acknowledge and deliver to the holder of any such mortgage, at any time upon request by such holder, any documents that may be required by such holder for the purpose of evidencing the
subordination of this Lease to any such Fee Mortgage, provided that such agreement shall contain non-disturbance language in favor of Tenant acceptable to Tenant. Such agreement shall contain commercially reasonable terms and conditions; subject to
the terms and conditions set forth at Section 46 hereof, Tenant 

  
 52 

 
agrees that the form of agreement attached as attached hereto as Exhibit “F” is a commercially reasonable form of agreement (the “SNDA”). In the event of a foreclosure sale
under any Fee Mortgage or in the event of the judicial sale of the Premises to collect indebtedness secured by any Fee Mortgage, or in the event of any transfer of the Leased Premises in lieu thereof, then, upon request of such Fee Mortgagee,
purchaser or transferee, Tenant shall attorn to and recognize as Landlord hereunder the party who, but for this Lease, would be entitled to possession of the Premises. The provisions of this Section 20.1 relating to subordination of this Lease
and to Tenant’s obligation to enter into SNDA agreements with Fee Mortgagees shall not apply to any Fee Mortgagee which are subordinate to one or more other Fee Mortgagee, unless the holders of such senior Fee Mortgagee shall consent thereto in
writing, and any such agreement made by Tenant with any holder of a Fee Mortgagee without such consent shall be voidable at the option of the holder of any such senior Fee Mortgage which shall not have given such consent. Landlord agrees that if and
to the extent that any consent or approval of a Fee Mortgagee is required under this Lease, only the consent or approval of the Fee Mortgagee then holding a first lien mortgage on the Premises shall be required. In addition, at the option of the
holder of any Fee Mortgage upon the Premises, this Lease may be senior to the lien of such Fee Mortgage and any Fee Mortgage subordinate to such Fee Mortgage. 
 20.2 TRANSFER OF PROPERTY. In the event of any transfer of Landlord’s interest in the Premises, other than a transfer for security purposes only, Landlord shall be automatically relieved of
any and all obligations and liabilities on the part of Landlord accruing from and after the date of such transfer and Tenant agrees to attorn to the transferee. Provided, Landlord may not transfer the Land or Premises or assign this Lease or its
obligations hereunder prior to completion of construction of the Building, the other Improvements and the Tenant Improvements. Nothing in this Section 20.2 shall impair or limit any right or remedy of Tenant expressly set forth in this Lease or
any right of Tenant for equitable relief. 
 21. SIGNAGE; ROOFTOP TELECOMMUNICATIONS EQUIPMENT; GENERATOR. 

21.1 SIGNAGE. So long as such signage, advertisement or notice complies with all applicable governmental requirements and the
Declaration, Tenant may erect, inscribe, paint or affix any sign, sticker, advertisement or notice on any part of the exterior of the Premises or other portions of the Premises without the consent of Landlord. Tenant shall bear all of the cost of
such signs and other items, including the cost of installing, maintaining and removing the same. All such signage shall be deemed to constitute Alterations and shall be subject to the terms and conditions of Section 10 hereof; provided however
that, in the absence of an Event of Default then existing by Tenant, in no event shall Tenant be required to remove such signage at the expiration or sooner termination of the Term. Tenant shall, at Tenant’s sole cost and expense, obtain all
applicable governmental permits and approvals for the erection and maintenance of all signs and exterior treatments upon the Premises. Any decorations, advertising media, or bars or other security installations visible from outside the Premises
shall be subject to Landlord’s approval and conform in all respects to all Requirements and the Declaration. So long as Tenant occupies at least 2 full floors of the Building, Tenant shall have the exclusive right to name or otherwise designate
the Building for advertising purposes during the Term. 

  
 53 

 21.2 ROOFTOP TELECOMMUNICATIONS EQUIPMENT. Tenant shall have the right, at any time
during the Term and at no additional Rent, to install, at Tenant’s sole cost and expense, antennae or other dish or satellite communications devices including cellular towers, together with equipment, cabling, conduits, pipes and fiber optics,
upon the roof of the Building; provided, however, that all such equipment shall be deemed to constitute Alterations and shall be subject to the terms and conditions of Section 10 hereof. 

21.3 GENERATOR. Tenant shall be entitled to install one or more additional emergency power systems (each, a “Generator”)
and one or more above-ground fuel storage tanks (each, together with the piping related thereto, an “FST”) in connection with the Generators, at Tenant’s sole cost and expense, at a location and with screening consented to by
Landlord, which consent shall not be unreasonably withheld, delayed or conditioned. 
 22. BROKER’S FEE. Tenant represents and
warrants that, with the exception of Jones Lang Lasalle Americas, Inc. (“Tenant’s Broker”), whose commission shall be paid by Landlord pursuant to separate agreement, Tenant has had no dealings, nor entered into any agreements, with
any person, entity, broker or finder in connection with the negotiation of this Lease, and no broker, person, or entity, other than Tenant’s Broker, is entitled to any commission or finder’s fee in connection with the negotiation of this
Lease on behalf of Tenant. Tenant and Landlord each agree to indemnify, defend and hold the other harmless from and against any claims, damages, costs, expenses, attorneys’ fees or liability for compensation or charges which may be claimed by
any broker, finder or other similar party, other than Tenant’s Broker as aforesaid, by reason of any dealings, actions or agreements of the indemnifying party. 
 23. ESTOPPEL CERTIFICATE. Each of Landlord and Tenant agrees, at any time and from time to time within twenty (20) days after Notice from the other party, to execute, acknowledge and deliver
to the requesting party or to any actual or prospective purchaser or mortgagee of the Leased Premises a written certificate stating that this Lease is unmodified and in full force and effect (or, if there have been modifications, that the same is in
full force and effect as modified and stating the modifications), stating the dates to which the Rent and any other payment due from Tenant shall have been paid in advance, if any, and providing such other information as the requesting party may
reasonably require, it being intended that such certificate delivered pursuant to this Section may be relied upon by the requesting party and any actual or prospective purchaser or Fee Mortgagee or lender, investor or purchaser of Tenant.

 24. RESERVED. 
 25.
LANDLORD’S ACCESS. Landlord and all Landlord Parties shall have the right to enter the Premises, at reasonable times and upon reasonable notice given to Tenant, for the purpose of inspecting the Premises, showing the Premises to prospective
purchasers, lenders or tenants (prospective tenants only during the last Lease Year of the Term), undertaking safety measures and making alterations, repairs, improvements or additions to the Premises that Landlord is permitted to make pursuant to
this Lease. During any such entry Landlord shall use reasonable efforts to avoid disruption to Tenant’s business operations. To the extent Tenant installs an access security system at the Premises (any such installation being an Alteration
subject to 

  
 54 

 
Section 10 hereof), Tenant shall provide Landlord with a key card or the control code for use in emergency situations. In the event of an emergency, Landlord may gain access to the Premises
by any reasonable means, and Landlord shall not be liable to Tenant for damage to the Premises or to Tenant’s property resulting from such access. Landlord may at any time place on or about the Building “for sale” signs, and Landlord
may at any time during the last one hundred eighty (180) days of the Term hereof place on or about the Premises “for lease” signs. 
 26. TENANT’S FINANCING. Landlord recognizes that Tenant may obtain financing in order to perform improvements or alteration to the Premises or to purchase equipment, or to otherwise operate
its business, and as security for such financing, Tenant may grant security interests in Tenant’s personal property, inventory, trade fixtures, laboratory equipment and removable fixtures and equipment located within the Premises. Landlord
hereby waives any rights it may have to any security interest, landlord lien or other statutory, prejudgment lien on such items, and Landlord agrees to execute, upon request, a confirmation of such waiver in form satisfactory to Tenant and/or
Tenant’s lenders. Nothing set forth in this Section 26 shall be construed to permit Tenant to assign, mortgage or otherwise encumber this Lease or the Premises. 
 27. PARTIAL INVALIDITY. If any term, covenant, condition or provision of this Lease, or the application thereof to any person or circumstance, shall at any time or to any extent be or become
invalid or unenforceable, nevertheless the remaining terms, covenants, conditions and provisions of this Lease, and the application thereof shall not be affected thereby and each remaining term, covenant, condition and provision of this Lease shall
be and remain valid and enforceable to the fullest extent permitted by law. 
 28. TIME OF THE ESSENCE. Time is of the essence with
respect to each of the obligations to be performed by Tenant and Landlord under this Lease. 
 29. INCORPORATION OF PRIOR AGREEMENTS.
This Lease, together with any addenda, schedules and Exhibits hereto, contains the entire agreement between the parties hereto, and Landlord and Tenant each acknowledge and agree that no agent, representative, salesman or officer of the other party
has authority to make or has made any statement, agreement or representation, either oral or written, in connection therewith, modifying, adding or changing the terms, conditions, covenants and provisions herein set forth. 

30. AMENDMENTS. No dealings between the parties or custom or usage of trade shall be permitted to contradict, vary, add to or modify the terms,
conditions, covenants and provisions of this Lease. No modifications of or amendment of this Lease shall be binding unless the same shall be in writing and signed by all of the parties hereto. 

31. NOTICES. All notices required or permitted by this Lease shall be in writing and may be delivered: (a) in person (by hand, by messenger
or by courier service); (b) by U.S. Postal Service regular mail; (c) by U.S. Postal Service certified mall, return receipt requested; (d) by U.S. Postal Service Express Mail, Federal Express or other overnight courier; or (e) by
facsimile transmission, with a confirmation copy by mail and shall be deemed sufficiently given if served 

  
 55 

 
in a manner specified in this Section 31. The “Addresses for Notices” set forth at Section 1 of this Lease shall be the address of each party for notice purposes; provided
that Landlord or Tenant may by written notice to the other specify a different address for notice purposes. A copy of all notices required or permitted to be given to Landlord hereunder shall be concurrently transmitted to such party or parties at
such addresses as Landlord may from time to time hereinafter designate by written notice to Tenant. Any notice sent by regular mail or by certified mail, return receipt requested, shall be deemed given three (3) days after deposited with the
U.S. Postal Service. Notices delivered by U.S. Express Mail, Federal Express or other courier shall be deemed given on the date delivered by the carrier to the appropriate party’s address for notice purposes. If any notice is transmitted by
facsimile transmission, the notice shall be deemed delivered two (2) days after the confirmation copy is deposited with the U.S. Postal Service. If notice is received on Saturday, Sunday or a legal holiday, it shall be deemed received on the
next business day. If delivery is rejected or refused, or if in connection with personal delivery, the written acknowledgment of personal delivery is refused to be given, or if the U.S. Postal Service is unable to deliver same because of changed
address of which no notice was given pursuant hereto, then such notice, demand or document shall be deemed to be delivered (whether or not actually received) on the first date of such rejection, refusal or inability to deliver. Either party may by
notice to the other in accordance with the foregoing specify a different address for payments or a different or additional address for delivery of notices. 
 32. WAIVERS. No waiver by Landlord or Tenant of any provision hereof shall be deemed a waiver of any other provision hereof or of any subsequent breach by Landlord or Tenant of the same or any
other provision. Landlord’s consent to, or approval of, any act shall not be deemed to render unnecessary the obtaining of Landlord’s consent to, or approval of any subsequent act by Tenant. The acceptance of Rent hereunder by Landlord
shall not be a waiver of any preceding breach by Tenant of any provision hereof, other than the failure of Tenant to pay the particular Rent so accepted, regardless of Landlord’s knowledge of such preceding breach at the time of acceptance of
such rent. No acceptance by Landlord of partial payment of any sum due from Tenant shall be deemed a waiver by Landlord of its right to receive the full amount due, nor shall any endorsement or statement on any check or accompanying letter from
Tenant be deemed an accord and satisfaction. Tenant hereby waives for Tenant and all those claiming under Tenant all rights now or hereafter existing to redeem by order or judgment of any court or by legal process or writ Tenant’s right of
occupancy of the Premises after any termination of this Lease. 
 33. BINDING EFFECT; CHOICE OF LAW. Except as herein otherwise expressly
provided, the terms, conditions, covenants and provisions hereof shall be binding upon and shall inure to the benefit of the heirs, executors, administrators, successors and assigns of Landlord and Tenant, respectively. The references contained in
this Lease to successors and assigns of Tenant shall not be construed to constitute a consent by Landlord to any assignment of this Lease by operation of law or otherwise and the inclusion of this Section 33 shall not impose or imply any
consent rights in Landlord. This Lease and the performance hereof shall be governed, interpreted, construed and regulated by the laws of the Commonwealth of Pennsylvania. 

  
 56 

 34. MERGER. The voluntary or other surrender of this Lease by Tenant, or a mutual cancellation
thereof, or a termination by Landlord, shall not result in the merger of Landlord’s and Tenant’s estates and shall, at the option of Landlord, terminate all or any existing subtenancies or may, at the option of Landlord, operate as an
assignment to Landlord of any or all of such subtenancies. 
 35. QUIET POSSESSION. Landlord covenants and warrants that so long as there
is no Event of Default by Tenant hereunder, Tenant shall have the right to peacefully have and enjoy the sole and exclusive possession of the Premises during the Term in accordance with the terms of this Lease. 

36. AUTHORITY. Landlord and Tenant each represent that each individual executing this Lease on its behalf is duly authorized to execute and
deliver this Lease on its behalf, that it is duly authorized to enter into this Lease, and that this Lease is enforceable against said entity in accordance with its terms. 
 37. CONFLICT. Except as otherwise provided herein to the contrary, any conflict between the printed provisions, exhibits, addenda or riders of this Lease and the typewritten or handwritten
provisions, if any, shall be controlled by the typewritten or handwritten provisions. 
 38. INTERPRETATION; RULES OF CONSTRUCTION. Both
parties acknowledge and agree that this Lease has been freely negotiated, and accordingly, this Lease shall be construed and interpreted without regard to any presumption or rule of construction against Landlord as the drafter of this Lease or
otherwise. As used herein, the singular shall include the plural; the use of masculine, feminine or neuter genders shall be deemed to include all genders. Any reference to the rights and authority of Landlord herein shall include such of
Landlord’s agents, servants, or employees to whom Landlord may delegate its rights or authority, and shall also include any mortgagee of Landlord which has reserved or to whom Landlord has delegated any such right or authority. The captions of
the Sections throughout this Lease are for convenience and reference only, and the words contained therein shall in no way be held to explain, modify, amplify or aid in the interpretation, construction or meaning of the terms, conditions, covenants
and provisions of this instrument. 
 39. MEMORANDUM OF LEASE. Contemporaneously herewith, Landlord and Tenant shall execute a Memorandum
of Lease substantially in the form attached hereto as Exhibit “G”. In the event it is determined pursuant to the terms of Section 1.2 above that the Initial Term shall expire on a date other than January 31, 2026, Landlord and
Tenant shall enter into an amendment to such Memorandum of Lease. Landlord shall have the right to record a memorandum of this Lease, and Tenant shall execute, acknowledge and deliver to Landlord for recording any memorandum prepared by Landlord.

 40. RELATIONSHIP OF PARTIES. Nothing contained in this Lease shall be deemed or construed by the parties hereto or by any third party
to create the relationship of principal and agent, partnership, joint venturer or any association between Landlord and Tenant. 

  
 57 

 41. CONFIDENTIALITY. Tenant acknowledges and agrees that the terms of this Lease are confidential and
constitute proprietary information of Landlord. Disclosure of the terms hereof could adversely affect the ability of Landlord to negotiate other leases. Landlord and Tenant each agree that it and its partners, officers, directors, employees,
brokers, and attorneys, if any, shall not disclose the terms and conditions of this Lease to any other person or entity except to the extent necessary for such party to comply with applicable laws and regulations (e.g., accounting matters and
securities laws) or as necessary for such party to obtain financing in connection with either party’s interest in or operations at the Premises. 
 42. FORCE MAJEURE. This Lease shall not be affected or impaired because Landlord or Tenant are unable to fulfill any of their obligations hereunder or are delayed in doing so, if such inability or
delay is caused by reason of a Force Majeure Event, and, except as otherwise set forth herein to the contrary, the time for Landlord’s or Tenant’s performance shall be extended for the period of any such delay. A “Force Majeure
Event” shall mean fire, earthquake, weather delays or other acts of God, strikes, boycotts, war, riot, insurrection, embargoes or industry shortages of equipment or materials, or shortages of labor (unless caused by the acts or omissions of
Landlord or a Landlord Party). Under no circumstances shall the financial condition of Tenant or Landlord, or such party’s ability to pay monetary amounts be considered a Force Majeure Event. 

43. PARKING. Landlord shall construct those portions of the Improvements consisting of the parking areas shown in the Improvement Plans and
Specifications and containing not less than five (5) parking spaces for each thousand (1,000) rentable square feet within the Building and complete the same by November 1, 2010; provided, Landlord agrees to provide at least 1/3 of the
proposed parking (reasonably accessible to the Building and in a safe and secure condition for Tenant’s use following Substantial Completion of the applicable portions of the work by Landlord hereunder scheduled to occur on October 1, 2010
and October 15, 2010, respectively, and during the continuing construction by Landlord of the remaining Improvements and Tenant Improvements to be constructed by Landlord hereunder) concurrently with the Substantial Completion of each portion
of the respective Improvements and Tenant Improvements required to be completed by Landlord on or before the respective October 1, 2010 and October 15, 2010 Anticipated Target Dates. Such spaces shall be provided free of charge during the
Term for the exclusive use of Tenant (subject to the use by Landlord of a de minimis number of spaces (designated by Tenant) in connection with the exercise of Landlord’s rights and obligations under this Lease. All parking facilities furnished
by Landlord shall be paved and striped surface parking with lighting, drainage, landscaping and accessory drives and walks, all as set forth in the Approved Plans. 
 44. LANDLORD’S REPRESENTATIONS AND WARRANTIES. Landlord represents and warrants to Tenant that (a) as of the date Landlord acquires title to the Property, Landlord shall own good
and marketable fee simple title to the Premises subject only to the Title Exceptions; (b) as of the Effective Date, Landlord has full power and authority to execute and deliver this Lease and to perform its obligations hereunder, and this Lease
has been authorized, executed and delivered by all necessary action of said limited liability company, and this Lease is binding on and enforceable against Landlord in accordance with its terms; (c) upon

  
 58 

 
Substantial Completion of the Building and other Improvements, the Building and all other Improvements and the Tenant Improvements will comply in all material respects with the Requirements;
(d) as of the Effective Date and as of the date of Substantial Completion of all the Improvements and the Tenant Improvements no litigation or proceedings are pending, or to the best of Landlord’s actual knowledge are threatened, against
Landlord or the Property or Premises which have or will have a material adverse effect on the ability of Landlord to perform Landlord’s obligations pursuant to, and as contemplated by, the terms and provisions of this Lease; (e) the
condition of the Building, Improvements and Tenant Improvements, as of the date of Substantial Completion, will conform in all material respects with all insurance requirements affecting the Building, Improvements and Tenant Improvements;
(f) as of the Effective Date and as of the date of Substantial Completion of all the Improvements and the Tenant Improvements , there will be no presently pending or levied special assessments, or any other public or quasi-public assessments or
lien payments (except general real estate taxes), that could be passed through to Tenant as Taxes under this Lease, and Landlord has received no notice of any such assessments or payments; (g) with respect to the Building, Improvements and
Tenant Improvements, the condition of the Building, the Improvements and Tenant Improvements, as of the date that the Building, Improvements and Tenant Improvements achieve Substantial Completion, will not violate the Title Exceptions; (h) to
the best of Landlord’s actual knowledge, as of the Effective Date, no condemnation of any portion of the Premises, nor any condemnation or relocation of any roadways abutting the Premises, nor any denial of access to the Premises from any point
of access to the Premises, will have commenced or will have been threatened by any governmental or quasi-governmental authority. The representations and warranties of Landlord under this Section 44 will survive for two (2) years after
Substantial Completion of all the Improvements and Tenant Improvements. 
 45. RIGHT OF FIRST OFFER 

45.1 If at any time, or from time to time, during the Term, Landlord shall desire to sell or convey its interest in the Premises, and so
long as there does not exist an Event of Default, Landlord shall notify Tenant of its intention (the “Right of First Offer Notice”). The Right of First Offer Notice shall specify the economic terms and conditions under which
Landlord is prepared to offer the property for sale. Tenant shall have the right to purchase the Premises on the terms set forth in the Right of First Offer Notice by giving Landlord written notice of such exercise (the “Right of First Offer
Acceptance”) within thirty (30) days after receipt of the Right of First Offer Notice that Tenant has elected to purchase the Premises. If Tenant does not so notify Landlord within such time period, such failure to notify shall be
deemed to constitute Tenant’s election not to purchase, and Landlord may sell or convey the Premises on terms and conditions substantially similar to the terms and conditions contained in the Right of First Offer Notice, at any time within
twelve (12) months of the Right of First Offer Notice, and at a price that equals or exceeds ninety five percent (95%) of the net proceeds payable to Landlord in the Right of First Offer Notice (inclusive of all customary closing costs and
expenses, including all real estate taxes payable, but excluding any brokerage commissions payable on a third party- sale but not payable in connection with the sale to Tenant). In the event that the Right of First Offer Notice contemplates the
assumption of existing debt by the Tenant, and Tenant has not provided 

  
 59 

 
the Right of First Refusal Acceptance, Landlord may, during said twelve (12) month period, continue to market the Premises with such assumable debt, and such assumable debt shall be deemed
to constitute net proceeds payable to Landlord hereunder for purposes of determining whether the price exceeds the ninety five percent (95%) requirement set forth in this Section 45.1. 

45.2 If Tenant timely provides the Right of First Offer Acceptance as set forth in Section 45.1, Landlord shall be bound to sell and
Tenant shall be bound to purchase the Premises (except as provided in the following sentence) in accordance with the terms of the Right of First Offer Notice, and the consummation of the purchase and sale (the “ROFO Closing”) shall
take place on or before the date that is ninety (90) days after Landlord’s receipt of Tenant’s Right of First Offer Acceptance. At the ROFO Closing, title to the Premises shall be conveyed by a special warranty deed in recordable form
executed by Landlord, subject to the following matters (other than those matters, if any, that are to be removed by Landlord or assumed by Tenant pursuant to the Right of First Offer Notice, except to the extent that such matters to be removed
pursuant to the Right of First Offer Notice were created by, caused by or result from the acts or omissions of Tenant, anyone claiming under Tenant, or their respective agents or employees): all Title Exceptions, all title matters created by, caused
by or resulting from the acts or omissions of Tenant, Tenant’s Permittees or anyone claiming under Tenant, or their respective agents or employees; provided, however, Landlord shall, except as otherwise set forth in the Right of First Offer
Notice, satisfy or cure all “Monetary Title Matters” (as hereinafter defined) at or prior to the ROFO Closing. “Monetary Title Matters” shall mean mortgages, security deeds, mechanic’s or materialmen’s liens and all
other monetary liens and judgments and claims (except to the extent created by, caused by or resulting from the acts or omissions of Tenant, anyone claiming under Tenant, or their respective agents or employees). In the event any objections are not
cured prior to or at the ROFO Closing, Tenant may, in addition to any other remedies available at law or equity, terminate its election to purchase the Premises by written notice to Landlord on or before the outside date for the ROFO Closing, or
take a credit against the purchase price in the amount of such Monetary Title Matter. All other terms of the ROFO Closing and the payment of costs in connection therewith shall be in accordance with the terms of the Right of First Offer Notice, as
applicable, and otherwise in accordance with the customs and practices of real estate closings in the Pittsburgh Region. 
 45.3
In the event that Tenant elects or is deemed to have elected not to purchase the Premises pursuant to Section 45.1, and Landlord conveys the Premises on substantially similar terms and conditions as those contained in the applicable Right of
First Offer Notice within twelve (12) months of such Right of First Offer Notice, and at a price that equals or exceeds ninety five percent (95%) of the price contained in such Right of First Offer Notice (exclusive of and without regard
to all closing costs and expenses, including all real estate transfer taxes and brokerage commissions), Tenant’s right of first offer under this Section 45 shall be deemed to have terminated and be of no further force and effect.

 46. ADDITIONAL CONTINGENCIES. This Lease contemplates that the form of SNDA and list of Title Exceptions will be attached as exhibits
to the Lease. Since neither are available as of the Effective Date and the parties, nonetheless, desire to proceed with the execution of the 

  
 60 

 
Lease without such exhibits, the parties have executed this Lease with the understanding that Landlord will provide to Tenant a survey, a proposed list of Title Exceptions and a form of SNDA on
or before September 10, 2009. Tenant shall thereafter have until the date that is five (5) business days following receipt of all such items from Landlord to review and approve, in writing, each such item, which approval shall not be
unreasonably withheld, conditioned or delayed. Following Tenant’s written approval of each of the Title Exceptions, survey and SNDA, the items will be initialed by the parties hereto and incorporated into this Lease as the applicable exhibits
hereto. If Tenant does not approve either or both of said forms of exhibits, Tenant may, on or before September 30, 2009, terminate the Lease upon not less than five (5) days written notice to Landlord, and in which event, all further
rights and obligations of the parties hereunder will terminate except that Landlord shall, to the extent applicable, reassign the Option Agreement to Tenant or, if title to the Land has been previously conveyed to Landlord, convey the Land to Tenant
and, in any such event, Landlord shall be responsible for all transfer taxes associated with such assignment and/or conveyance. 
 47.
COUNTERPARTS; FACSIMILE. This Lease may be executed in any number of counterparts, and by each of the parties on separate counterparts, each of which, when so executed, shall be deemed an original, but all of which shall constitute but one and
the same instrument. Delivery of an executed counterpart of this Lease by telefacsimile shall be equally as effective as delivery of a manually executed counterpart of this Lease. Any party delivering an executed counterpart of this Lease by
telefacsimile shall also deliver a manually executed counterpart of this Lease, but the failure to deliver a manually executed counterpart shall not affect the validity, enforceability or binding effect of this Lease. 

48. PARTIES’ ACKNOWLEDGMENT. LANDLORD AND TENANT ACKNOWLEDGE THAT THEY HAVE CAREFULLY READ AND REVIEWED THIS LEASE AND EACH TERM AND
PROVISION CONTAINED HEREIN AND, BY EXECUTION OF THIS LEASE, SHOW THEIR INFORMED AND VOLUNTARY CONSENT THERETO. THE PARTIES HEREBY AGREE THAT, AT THE TIME THIS LEASE IS EXECUTED, THE TERMS OF THIS LEASE ARE COMMERCIALLY REASONABLE AND EFFECTUATE THE
INTENT AND PURPOSE OF LANDLORD AND TENANT WITH RESPECT TO THE PREMISES. TENANT ACKNOWLEDGES THAT IT HAS BEEN GIVEN THE OPPORTUNITY TO HAVE THIS LEASE REVIEWED BY ITS LEGAL COUNSEL PRIOR TO ITS EXECUTION. PREPARATION OF THIS LEASE BY LANDLORD OR
LANDLORD’S AGENT AND SUBMISSION OF SAME TO TENANT SHALL NOT BE DEEMED AN OFFER BY LANDLORD TO LEASE THE PREMISES TO TENANT OR THE GRANT OF AN OPTION TO TENANT TO LEASE THE PREMISES. THIS LEASE SHALL BECOME BINDING UPON LANDLORD ONLY WHEN FULLY
EXECUTED BY BOTH PARTIES AND WHEN LANDLORD HAS DELIVERED A FULLY EXECUTED ORIGINAL OF THIS LEASE TO TENANT. 
 [THE REMAINDER OF THIS PAGE
INTENTIONALLY LEFT BLANK; SIGNATURES FOLLOW ON THE NEXT PAGE] 

  
 61 

 [SIGNATURE PAGE TO THAT CERTAIN LEASE AGREEMENT BETWEEN CRANWOODS-WST, LTD., AS LANDLORD, AND WESTINGHOUSE
ELECTRIC COMPANY, AS TENANT; LOT NO. 3 IN THE REVISION NO. 2 TO CRANBERRY WOODS PLAN NO. 1] 
 IN WITNESS WHEREOF, the parties
have caused this Lease Agreement to be executed by their duly authorized representatives as of the dates below written. 
  

							
	ATTEST/WITNESS	 		 	LANDLORD:
			
		 		 	 CRANWOODS-WST, LTD., a Pennsylvania
 limited partnership

				
		 		 	By:	 	 TFG Investments IV, LLC, a Pennsylvania
 limited partnership, its sole general partner

				
		 		 	By:	 	 JTMK-WST, Ltd., an Ohio limited partnership,
 its sole member

				
		 		 	By:	 	 TFG Development, LLC, an Ohio limited
 liability company, its sole general partner

				
		 		 	By:	 	 /s/ John J. Ferchill

				
		 		 	Name:	 	 John J. Ferchill

				
		 		 	Its:	 	 President

				
		 		 	Dated:	 	 9/2/09

  
 62 

 
			
	TENANT:
	
	 WESTINGHOUSE ELECTRIC COMPANY
 LLC

		
	By:	 	 /s/ Aris S. Candris

		
	Name:	 	 Aris S. Candris

		
	Its:	 	 President and Chief Executive Officer

		
	Dated:	 	 August 31, 2009

  
 63

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00201-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00201-of-00352.parquet"}]]