Document:

<PAGE>

                                                                   Exhibit 10.11

                           SOFTWARE LICENSE AGREEMENT

This SOFTWARE LICENSE AGREEMENT (the "Agreement") is dated as of the _12th day
of _December, 2003 ("Effective Date") and is made by and between ALLTEL
COMMUNICATIONS, INC., a Delaware corporation, located at One Allied Drive,
Little Rock, Arkansas 72211, USA ("ALLTEL") and Dwango North America, Inc., a
Texas corporation whose principal place of business is located at 5847 San
Felipe St., Suite 2825, Houston, Texas 77057-3000 ("Developer").

Capitalized terms used herein shall have the same meaning ascribed to them in
the BREW Developer Agreement between QUALCOMM and the Developer.

     1.   License Grant.

               1.1   Grant of License to BREW Software. Developer hereby grants
to ALLTEL a fully paid-up, royalty free, within the United States, Canada and
Mexico, assignable, non-exclusive, right and license for the term of the
Agreement to: (i) to reproduce and include each BREW Application and related
documentation developed by Developer in the Carrier Catalog in object code
format only; (ii) to distribute through multiple tiers of distribution to
ALLTEL's end user subscribers ("End Users") an unlimited number of copies of
such BREW Applications in object code form only and all related documentation
and (iii) use and reproduce all logos, marks, screen shots, literature,
demonstration programs and other related items. With respect to each BREW
Application, the foregoing license shall commence on the date the BREW
Applications is downloaded into the ALLTEL Catalog and will terminate on the
earlier of (a) the date the BREW Application is removed from the ALLTEL Catalog,
or (b) the date of termination of this ALLTEL License Agreement. Any such
termination shall not terminate an End User's right to continue to use a BREW
Application downloaded by the End User prior to such termination.

               1.2   License Restrictions. Except to the extent permitted by
this Agreement or by applicable law, ALLTEL agrees (i) it will not otherwise
distribute BREW Applications; (ii) it will not modify, reverse assemble,
decompile or reverse engineer a BREW Application, and (iii) it will not remove,
efface or obscure any copyright notices, logos or other proprietary notices or
legends included in a BREW Application.

     2.   Removal of a BREW Application from the Carrier Catalog.

               2.1   Developer's Requested Removal of a BREW Application from
the Carrier Catalog. Developer shall provide ALLTEL thirty (30) days prior
written notice that Developer desires to remove a BREW Application from the
Carrier Catalog. Developer acknowledges and agrees that ALLTEL's removal of any
BREW Application from the Carrier Catalog does not terminate the rights or
licenses of End Users who obtained such BREW Application from ALLTEL prior to
the date of removal.

               2.2   ALLTEL's Removal of a BREW Application from the Carrier
Catalog. ALLTEL may remove a BREW Application from the Carrier Catalog at any
time and for any reason in the ALLTEL's sole discretion. Developer acknowledges
and agrees that ALLTEL's removal of any BREW Application from the Carrier
Catalog does not terminate the rights or licenses of End Users who obtained such
BREW Application from ALLTEL prior to the date of removal.

               2.3   Developers Refund for Applications. In the event that
ALLTEL or Developer removes a BREW Application or Extension for any reason from
an End User, Developer will be responsible for refunding its revenues associated
with that BREW Application or Extension to Qualcomm.

                                  Page 1 of 10

<PAGE>

     3.   BREW Extensions. For purposes of Section 1 (License Grant) and
Section 2 (Removal of BREW Applications from the Carrier Catalog) the term "BREW
Application" includes any BREW Extensions used, accessed or called by a BREW
Application.

     4.   The DAP.

               4.1   DAP Negotiation. Developer and ALLTEL may choose, from time
to time, to discuss and negotiate a DAP for a particular BREW Application that
will apply only to ALLTEL. If Developer and ALLTEL agree to an alternate DAP for
a BREW Application, Developer will submit an alternate Pricing Template for the
BREW Application. ALLTEL shall have the right in its sole discretion to charge
any price to the End-Users so long as the Developer and QUALCOMM receive the
proportionate share of the DAP.

               4.2   No Fees. No payments shall be made by either Developer or
ALLTEL to the other under this Agreement, or for any use or development of BREW
Applications. Developer shall look solely to QUALCOMM for payment for the
applications licensed under this Agreement. Developer shall not charge ALLTEL
any fees for those BREW Applications which are utilized by ALLTEL employees
solely for sales and demonstration purposes (not to exceed 3,000 ALLTEL
employees in any calendar month, unless otherwise agreed to by the parties in
writing).

               4.3   Co-op Advertising. Developer agrees to pay for advertising,
placement fees and any other such fees, as mutually agreed. Such
advertising-related payments shall be made by Developer directly to ALLTEL.
Developer will be solely responsible for all fees, including layout, printing,
shipping, etc. for other advertising materials, such as literature and training
materials. Such advertising materials shall meet ALLTEL's reasonable
specification, which ALLTEL may change from time-to-time. In no event shall
ALLTEL obligated to display such literature without ALLTEL's prior written
consent.

     5.   Ownership. Subject to the licenses granted in this Agreement and the
End User License Agreement, Developer and its licensors are and will remain the
owner of all right, title and interest in and to each BREW Application and BREW
Extension, including all intellectual property therein.

     6.   Representations and Warranties.

               6.1   No Viruses. Developer represents and warrants to ALLTEL
that each BREW Application developed by Developer will be free from (i) viruses
and code that disrupts, disables, harms, erases the memory of, or otherwise
impedes the operation, features or functions of any software, firmware,
hardware, wireless device, computer system or network, or (ii) code that would
permit Developer or any third party to access the BREW Application to cause the
disablement or impairment of the BREW Application or a BREW Device. In the event
of a breach of the foregoing warranty, Developer will be liable and responsible
for all actual losses, costs, expenses and damages, including, without
limitation, the cost of recalling BREW Devices.

               6.2   BREW Application Warranty. Each BREW Application will be
deemed accepted by ALLTEL at the time it is downloaded by the ALLTEL from
QUALCOMM. Developer warrants and represents: (1) that the BREW Application shall
conform in all respects with the requirements of this Agreement; (2) Developer
has the legal right to grant ALLTEL the rights and interests in this Agreement
and that the BREW Application is free from any claim of infringement or other
intellectual property related claim by any third party, and further agrees that
it shall defend, indemnify and hold ALLTEL and its End-Users harmless from any
third party infringement claims relating to the BREW Application in accordance
with Section 8.1 herein. Developer also warrants that it has full power, and
rights to and in, the associated marks and names of the BREW Application; (3)
that BREW Application shall be free from

                                  Page 2 of 10

<PAGE>

defects, including any latent defects, in material, engineering and workmanship
which arise under proper and normal use; (4) that if the BREW Application
contains any authorization codes ("keys") embedded therein, Developer agrees
that these codes, upon expiration, will not result in the disruption of ALLTEL's
or End-User's authorized use of the BREW Application. These codes, if any, will
only be "soft stop" in nature (i.e.: display warning messages); (5) that the
BREW Application as licensed hereunder does not contain any computer viruses;
(6) that the BREW Application does not contain any timer, clock, or other code
which could cause it to cease functioning unless the existence of such code is
disclosed by Developer; (7) that BREW Application and any related services
performed by Developer shall comply with all laws and regulations relating to
the BREW Application or services; (8) any enhancement, fixes, repairs, upgrades,
patches or other services related to the BREW Application licensed hereunder
will comply with the warranties set forth in this Section 6.2; (9) that at the
time of signing this Agreement, Developer is not aware of any claims against
Developer regarding the BREW Application; (10) all services provided to carrier
by Developer shall be provided in a professional and workmanlike manner; and
(11) the BREW Application shall perform in accordance with all written
descriptions and documentation provided by or authored by Developer, including
written representations made by Developer to ALLTEL. Developer warrants to
ALLTEL, during the term of this Agreement or any renewal thereof that after
ALLTEL downloads a copy of a BREW Application from QUALCOMM, that the BREW
Application will perform substantially in accordance with the applicable
documentation. In the event of a breach of this warranty, ALLTEL must provide
written notice to Developer within the warranty period and Developer will, after
receipt of such notice (i) repair the BREW Application, (ii) replace the BREW
Application with a BREW Application which conforms to the foregoing warranty, or
(iii) terminate this Agreement with respect to the BREW Application. Developer
does not warrant that the operation of a BREW Application will be uninterrupted
or error free.

               6.3   Warranty Remedies. Developer will provide the following
warranty remedies provided ALLTEL notifies Developer during the specified
warranty period, of any non-conformance to the above warranties.

               (i)  Developer shall first attempt to promptly repair, remedy or
               replace defective BREW Application so that they function in
               accordance with the documentation as provided by Developer.

               (ii) If, after reasonable attempts, Developer is unable to
               otherwise repair, remedy, or replace any such BREW Application
               under Section 6.3(c) (i), then Developer shall promptly refund
               the full purchase price. In the event that ALLTEL exercises any
               remedy for any breach of warranty, ALLTEL shall not be precluded
               from seeking any and all remedies available to ALLTEL at law or
               in equity.

     7.   DISCLAIMER. EXCEPT FOR THE EXPRESS WARRANTIES AND REPRESENTATIONS SET
FORTH IN THIS AGREEMENT, NEITHER DEVELOPER, ITS LICENSORS NOR ALLTEL MAKE ANY
OTHER WARRANTIES, EXPRESS OR IMPLIED. EACH PARTY EXPRESSLY DISCLAIMS ALL OTHER
WARRANTIES AND REPRESENTATIONS, WHETHER EXPRESS, IMPLIED, OR STATUTORY,
INCLUDING WITHOUT LIMITATION THE IMPLIED WARRANTIES OF MERCHANTIBILITY, FITNESS
FOR A PARTICULAR.

     8.   Indemnification.

               8.1   Indemnification. Developer hereby agrees to defend,
indemnify and hold harmless ALLTEL and its End Users (each, an "Indemnified
Party") against any and all claims, demands, causes

                                  Page 3 of 10

<PAGE>

of action, damages, costs, expenses, penalties, losses and liabilities (whether
under a theory of negligence, strict liability, contract or otherwise) incurred
by an Indemnified Party (including reasonable attorney fees) arising out of,
resulting from or related to (i) a breach of any representation or warranty
under this Agreement or (ii) any authorized use, reproduction or distribution of
a BREW Application or BREW Application documentation developed by Developer
which causes an infringement of any patent, copyright, trademark, trade secret,
or other property rights of any third parties arising in any jurisdiction
throughout the world. ALLTEL agrees to provide Developer with written notice of
any third party claim subject to indemnification, allowing Developer to have
sole control of the defense of such claim and any resulting disposition or
settlement of such claim; provided, however that the ALLTEL may participate in
the defense of a claim on an equal basis at its own expense. Any disposition or
settlement that imposes any liability on or affects the rights of ALLTEL will
require the ALLTEL's prior written consent.

               8.2   Remedies. If Developer determines that a BREW Application
becomes, or is likely to become, the subject of an infringement claim or action,
Developer shall: (i) first attempt to procure, at no cost to ALLTEL, the right
to continue distributing such BREW Application, or portion thereof, as
applicable; (ii) then second if 8.2(i) is not possible after Developer has
exerted commercially reasonable efforts, then Developer shall replace or modify
the BREW Application, or portion therefor, as applicable to render it
non-infringing, provided there is no material loss of functionality; or (iii)
after Developer has exerted commercially reasonable efforts and neither 8.2(i)
nor 8.2(ii) above are not commercially feasible, (a) ALLTEL shall immediately
remove the BREW Application from the Carrier Catalog upon Developer's written
request; and (b) Developer may terminate this Agreement for such BREW
Application.

     9.   Liability Limitations.

               9.1   EXECPT FOR THE DEVELOPERS INDEMNIFICATION OBLIGATIONS SET
FORTH IN SECTION 8, ABOVE, EITHER PARTY'S LIABILITY FOR ANY CLAIM OR CAUSE OF
ACTION WHETHER BASED IN CONTRACT, TORT OR OTHERWISE WHICH ARISES UNDER OR IS
RELATED TO THIS AGREEMENT SHALL BE LIMITED TO SUCH PARTY'S DIRECT OUT-OF-POCKET
DAMAGES, ACTUALLY INCURRED, WHICH UNDER NO CIRCUMSTANCES SHALL EXCEED, IN THE
AGGREGATE, THE AMOUNT OF SUCH PARTY'S SHARE OF THE DAP UNDER THIS AGREEMENT.

               9.2   IN NO EVENT SHALL EITHER PARTY BE LIABLE FOR INDIRECT,
SPECIAL, PUNITIVE, INCIDENTAL OR CONSEQUENTIAL DAMAGES OF ANY KIND WHATSOEVER OR
THE CLAIMS OR EXECPT FOR THE DEVELOPERS INDEMNIFICATION OBLIGATIONS SET FORTH IN
SECTION 8, ABOVE, OR DEMANDS MADE BY ANY THIRD PARTIES, WHETHER OR NOT SUCH
PARTY HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES.

     10.  Term and Termination.

               10.1  Term. This Agreement will become in effect on the date
ALLTEL downloads a BREW Application developed by Developer from the BREW Catalog
and will remain in effect until terminated as provided in this Agreement.

               10.2  Termination. Either Party may terminate this Agreement,
with or without cause, upon thirty (30) days prior written notice to the other
Party. Upon termination of this Agreement, ALLTEL agrees (i) to remove from the
Carrier Catalog all BREW Applications developed by Developer; and (ii) to cease
permitting End Users (or any other person) from downloading BREW Applications
from the Carrier Catalog. Developer acknowledges and agrees that the termination
of this Agreement does not

                                  Page 4 of 10

<PAGE>

terminate the rights or licenses of End Users who obtained a BREW Application
from ALLTEL prior to the date of termination of this Agreement.

               10.3  Survival. Upon any termination or expiration of this
Agreement, the following provisions will survive any such termination or
expiration: Sections titled ("Ownership"), ("Indemnification"), ("Liability
Limitations"), ("Term and Termination"), and ("General").

     11.  General.

               11.1  Relationship of Parties. Developer and ALLTEL are
independent contractors and this Agreement shall not establish any relationship
of partnership, joint venture, employment, franchise, or agency between
Developer and ALLTEL. Neither Developer nor ALLTEL shall have the power to bind
the other or incur obligations on the other's behalf without the other's prior
written consent.

               11.2  Export Control Compliance. ALLTEL agrees that it will not
export or re-export a BREW Application, or any portion of thereof, in any form
in violation of the laws and regulations of the United States or any other
jurisdiction or country without the appropriate United States and foreign
government export or import licenses or other official authorization.

               11.3  Assignment. Neither Party shall assign this Agreement in
whole or in part without the prior written consent of the other party. However,
both Parties shall have the right to assign this Agreement to an affiliate or
subsidiary. This Agreement will bind and inure to the benefit of the respective
successors and permitted assigns of Developer or ALLTEL.

               11.4  Entire Agreement and Amendment. This Agreement completely
and exclusively states the agreement between Developer and ALLTEL regarding its
subject matter. Excluding the previously executed non-disclosure agreement
between the parties, this Agreement supersedes and governs all prior or
contemporaneous understandings, representations, agreements, or other
communications between Developer and ALLTEL, oral or written, regarding such
subject matter.

               11.5  Severability. If any one or more of the provisions
contained herein shall for any reason be held to be unenforceable in any respect
under law, such unenforceability shall not affect any other provision of this
Agreement, but this Agreement shall be construed as if such unenforceable
provision or provisions had never been contained herein, provided that the
removal of such offending term or provision does not materially alter the
burdens or benefits of either of the parties under this Agreement or any
Exhibit.

               11.6  Third Party Beneficiaries. The provisions of this Agreement
are for the benefit of the parties and not for any other person. Should any
third party institute proceedings, this Agreement shall not provide any such
person with any remedy, claim, liability, reimbursement, cause of action, or
other right.

               11.7  Governing Law; Forum Selection; Consent of Jurisdiction.
This Agreement shall be governed by and construed in accordance with the laws of
the State of Arkansas, without regard to its conflicts of law principles. All
judicial proceedings to be brought with respect to the Agreement or any other
dispute between the parties hereto shall be brought in any state or federal
court located in Little Rock, Arkansas (the "Court") and by execution and
delivery of this Agreement, the parties hereto each accepts generally and
unconditionally the exclusive jurisdiction of the Court and irrevocably waives
any objection (including, without limitation, any objection of the laying of
venue based on the grounds of forum non-conveniens) which either of them may now
have or hereafter have to the bringing of any such action or proceeding with
respect to this Agreement or any other dispute in the Court.

                                  Page 5 of 10

<PAGE>

               11.8  Executed in Counterparts. This Agreement may be executed in
counterparts, each of which shall be an original, but such counterparts shall
together constitute but one and the same document.

               11.9  Construction. The headings and numbering of sections in
this Agreement are for convenience only and shall not be construed to define or
limit any of the terms or affect the scope, meaning or interpretation of this
Agreement or the particular section to which they relate. This Agreement and the
provisions contained herein shall not be construed or interpreted for or against
any party because that party drafted or caused its legal representative to draft
any of its provisions.

               11.10 Waivers. No waiver of any provisions of this Agreement and
no consent to any default under this Agreement shall be effective unless the
same shall be in writing and signed by or on behalf of the party against whom
such waiver or consent is claimed. No course of dealing or failure of any party
to strictly enforce any term, right or condition of this Agreement shall be
construed as a waiver of such term, right or condition. Waiver by either party
of any default by the other party shall not be deemed a waiver of any other
default. No course of dealing shall be deemed to amend the Agreement in the
absence of any writing signed by duly authorized representatives of each party.

               11.11 Remedies Cumulative. Unless otherwise provided for under
this Agreement, all rights of termination or cancellation, or other remedies set
forth in this Agreement, are cumulative and are not intended to be exclusive of
other remedies to which the injured party may be entitled by law or equity in
case of any breach or threatened breach by the other party of any provision in
this Agreement. Use of one or more remedies shall not bar use of any other
remedy for the purpose of enforcing any provision of this Agreement.

               11.12 Press Releases. The parties shall consult with each other
in preparing any press release, public announcement, news media response or
other form of release of information concerning this Agreement or the
transactions contemplated hereby that is intended to provide such information to
the news media or the public (a "Press Release"). Neither party shall issue or
cause the publication of any such Press Release without the prior written
consent of the other party; except that nothing herein will prohibit either
party from issuing or causing publication of any such Press Release to the
extent that such action is required by applicable law or the rules of any
national stock exchange applicable to such party or its Affiliates, in which
case the party wishing to make such disclosure will, if practicable under the
circumstances, notify the other party of the proposed time of issuance of such
Press Release and consult with and allow the other party reasonable time to
comment on such Press Release in advance of its issuance.

               11.13 Support. At no additional charge to ALLTEL, Developer will
provide ALLTEL and End-Users support for general questions and issues via e-mail
and via phone seven (7) days per week at least 7 AM Central Time to 7 PM Central
Time. Developer must also provide Frequently Asked Questions (FAQ) to ALLTEL
when submitting a BREW Application for consideration. Upon the launch of
networked and/or multiplayer BREW Applications, the Parties agree to the Service
Level Agreement in Exhibit A of this Agreement.

               11.14 Taxes. All charges and fees to be paid under this Agreement
are exclusive of any applicable sales, use, value added, excise, services or
other tax which may be assessed currently or in the future on BREW Applications
provided under this Agreement. All taxes of any nature that are attributable to
payments due to Developer under this Agreement except taxes imposed on the net
income of any other third party, including without limitation ALLTEL, shall be
borne by Developer. If a sales, use, value added, excise, goods and/or services
tax is assessed on BREW Applications provided to Developer under this Agreement.
Developer will pay directly, reimburse or indemnify ALLTEL for such

                                  Page 6 of 10

<PAGE>

taxes, as well as any applicable interest and penalties. The parties will
cooperate with each other in determining the extent to which any tax is due and
owing under the circumstances and shall provide and make available to each other
any withholding certificates, information regarding the location of use of the
BREW Applications and any other exemption certificates or information reasonably
requested by either party.

     IN WITNESS WHEREOF, the parties have executed this Agreement as of the
Effective Date by their duly authorized representatives.

ALLTEL COMMUNICATIONS, INC.               DWANGO NORTH AMERICA, INC.

By:      /s/ Roger R. Woziwodzki          By:      /s/ Rick J. Hennessey
       -------------------------------           -------------------------------
Name:    Roger R. Woziwodzki              Name:    Rick J. Hennessey
       -------------------------------           -------------------------------
Title:   Director - Wireless Data         Title:   President
         Products                                -------------------------------
       -------------------------------    Date:    12-16-03
Date:    12/19/03                                -------------------------------
       -------------------------------

                                  Page 7 of 10

<PAGE>

Exhibit A. SERVICE LEVEL AGREEMENT (SLA)

Purpose:
ALLTEL and Developer agree to the identified levels of service to be
provided and to inform operations personnel who will need specific
information to support the BREW Applications.

Support and Uptime:
Developer shall use commercially reasonable efforts to maintain all of its
necessary hardware, software, bandwidth, and other facilities and equipment
to provide the BREW Application in accordance with the Agreement. Developer
shall also provide ALLTEL with access to technical support 24 hours a day
365 days per year for Major Incident Management. The service shall be
available 99.99% of the year. The calculation of availability excludes
scheduled downtimes.

Major Incident Management:
ALLTEL agrees to host first level support for customers who are
experiencing difficulty with the BREW Application, unless submitted via
e-mail directly to Developer. ACI IT User Support will report problems with
Developer's service to the Developer's NOC.

The following outlines major incident prioritization:

--------------------------------------------------------------------------------
Priority                                          Initial       Target    Status
 Level     Error Type         Description         Response    Resolution Reports
--------------------------------------------------------------------------------
   1      Fatal Error  . There is a service      30 minutes    2 hours   Hourly
                         outage
                       . There is a reoccurring
                         outage of the service
                       . Complete loss of
                         Developers BREW
                         Applications
                       . Unable to provision
                         customer
--------------------------------------------------------------------------------
   2        Severe     . Applications are        30 minutes    4 hours   Hourly
            Impact       jumbled, outdated,
                         repeated, and
                         ineffective to all
                         users of the system
                       . Service is
                         inconsistent
                       . Major failure of an
                         important product
                         feature, including but
                         not limited to:
                       ___________________
                       ___________________
                       ___________________
                       ___________________
                       . Performance results
                         are materially
                         different from those
                         outlined in the
                         agreement
--------------------------------------------------------------------------------
   3       Degraded    . Feeds are jumbled,      30 minutes    8 hours   Every 2
           Operation     outdated, repeated,                              hours
                         and ineffective to an
                         isolated number of
                         users of the system
                       . Operational impact on
                         support or
                         administrative tools,
                         non-customer facing
--------------------------------------------------------------------------------

                                  Page 8 of 10

<PAGE>

The first update for every type of incident Developer should provide the
following information:
..  Current status of repair
..  Estimated time of repair
..  Complete description of service impact
If resolved:
..  How was the issue fixed?
..  Is this the first time the issue has occurred?

Developer will maintain a log of all issues that occur during the Term of
service and make the log available to ALLTEL upon ALLTEL's request

Service Expectation:

In the event that a Fatal or Severe Error is not resolved in accordance
with the corresponding Target Resolution Time above, Developer will
reimburse ALLTEL $5,000 for each twenty-four (24) hour period in excess of
the Target Resolution, until said error is resolved to ALLTEL's
satisfaction.

Developer must alert ALLTEL in writing of any maintenance or potential
interruptions in service with a minimum of forty-eight (48) hours notice.

Developer Escalation:

[Developer to add information]

ALLTEL Escalation:

Internal ALLTEL sources and Developer will notify the ACI IT User Support
Group at 501-905-8569, option 2 for outages. If long waits are experienced
when dialing 501-905-8569, a back up number 501-905-2887 may be dialed
during business hours. The ACI IT User Support group will notify internal
personnel by Internal e-mail and urgent voice mail of outages via a
distribution list. When the outage is cleared a second message will notify
ALLTEL personnel the problem has been corrected.

<TABLE>
<CAPTION>
-------------------------------------------------------------------------------------------------
   Group                    Function                    Hours of Operation CST       Phone Number
-------------------------------------------------------------------------------------------------
<S>            <C>                                  <C>                           <C>
ACI IT User    The ACI IT User Support Group will   Hours are 7:00 am - 10:00 pm  501-905-8569
Support Group  act as the central point of contact  Mon-Fri                       option 2
               for problems.                        7:30 am - 5:30 pm Sat         or
               The ACI IT User Support group will   12:00 pm - 5:00 pm Sun.       501-905-2887
               notify users about outages via the   All times are CST.            (business hours
               Web-Unwired and Internet             After hours on call.          only)
               distribution lists.
-------------------------------------------------------------------------------------------------
</TABLE>

                    ALLTEL CONTACTS (For Developer Use Only)

----------------------------------------------------------------------------
                                 ALLTEL Phone Numbers
all Types    ALLTEL Department          to Use          Hours of Operation
----------------------------------------------------------------------------
Customer     Refer to Customer  1-800-ALLTEL-1          7 x 24
Issues       Care
----------------------------------------------------------------------------

                                   Page 9 of 10

<PAGE>

----------------------------------------------------------------------------
                                                        Hours are 7:00 am
                                                        - 10:00 pm Mon-Fri
                                501-905-8569 option 2   7:30 am - 5:30 pm
                                or                      Sat
Operational  ACI IT user        501-905-2887 (business  12:00 pm - 5:00 pm
Issues       support group      hours only)             Sun.
                                                        All times are CST.
                                                        After hours on call.
----------------------------------------------------------------------------

                                 Page 10 of 10<PAGE>

                                                                   Exhibit 10.12

                         Direct Bill Services Agreement

          This Agreement ("Agreement") is made as of the last date and year
     specified on the signature page hereof, by and between Cingular Wireless
     LLC, a Delaware Limited Liability Company ("Cingular"), and Dwango North
     America, Inc. a Texas corporation, ("Customer").

     Whereas, Cingular provides a service which will allows Customer to sell to
     Cingular subscribers Information Services, including graphics, games, ring
     tones and other content which can be used, played or displayed on certain
     wireless enabled devices ("Information Services");

     Whereas, as a part of such service, Cingular will include on certain of its
     subscribers' bills for wireless services, the charges imposed by Customer
     for Information Services ("DirectBill Service")

     Whereas, Customer wishes to subscribe to Cingular's DirectBill Service."

     Now, therefore, for and in consideration of the premises and other good and
     valuable consideration, the parties agree as follows:

          1.    DEFINITIONS

          1.1   "Affiliate" shall mean any entity which, directly or indirectly,
                is controlled by Cingular, or any partnership, joint venture,
                consortium or other such entity in which Cingular or its
                Affiliates have any material form of ownership or any managerial
                interest. For purposes of this definition, "material form of
                ownership" shall be deemed to include partnerships, joint
                ventures, consortiums or other entities in which Cingular or its
                Affiliates have at least a thirty percent (30%) ownership
                interest.

          1.2   "Cingular Marks" means the trademarks, service marks, logos and
                other distinctive brand marks of Cingular or its Affiliates that
                are used in or relate to Cingular's business.

          1.3   "Customer" means the entity named above and identified as
                Customer. Customer represents that it does business under the
                following names: Dwango Wireless. Customer represents that its
                address is: 5847 San Felipe St., Suite 2825, Houston, Texas
                77057-3000. Customer represent that the following is a toll-free
                number at which DirectBill Subscribers may contact Customer to
                discuss problems with Customer's Information Services.

          1.4   "DirectBill Subscribers" means Cingular wireless Subscribers who
                have registered to have Information Services billed on their
                wireless phone account.

          1.5   "Unsuitable Information Services" means Information Services
                that Cingular may at its sole discretion determine to be
                inappropriate for billing by Cingular, including images or
                content that is in any way unlawful, harmful, threatening,
                defamatory, obscene, harassing, or racially, ethically or

                                        1

<PAGE>

                otherwise objectionable; Information Services that facilitate
                illegal activity, depict sexually explicit images, promote
                violence, promote discrimination, promote illegal activities, or
                incorporate any materials that infringe or assist others to
                infringe on any copyright, trademark, or other intellectual
                property rights.

          2.    SCOPE OF SERVICES

          2.1   Cingular shall allow its Subscribers to register for DirectBill
                service through a website maintained by Cingular. Upon
                registration and selection of a pin code DirectBill Subscribers
                may purchase Information Services.

          2.2   Cingular through its vendor, Qpass Inc. will authenticate
                DirectBill Subscribers and deliver the Information Services to
                the DirectBill Subscriber initiating the purchase. A description
                of the authorization and process of delivery of the Information
                Services is shown in the DirectBill QuickStart Guide which will
                be provided to Customer upon execution of this agreement, and
                can be found at alliance.cingularinteractive.com. This guide is
                subject to revision at any time with reasonable notification to
                Customer.

          2.3   The Information Services approved by Cingular, and which can be
                offered and delivered by the Customer to DirectBill Subscribers
                are shown in Exhibit 1 ("Approved Information Services") of this
                agreement.

          2.4   It is expressly understood and agreed that this Agreement does
                not grant to either party any exclusive privileges or rights and
                that either party may participate in similar business
                arrangements and for similar content as described herein and
                contract with other organizations in association therewith.

          3.    CINGULAR UNDERTAKING AND REPRESENTATIONS

          3.1   Cingular shall include on its monthly bills charges incurred by
                DirectBill Subscribers for the purchase of Information Services.

          3.2   Cingular shall collect from DirectBill Subscribers the charges
                for Information Services.

          3.3   Cingular will provide its traditional billing related Tier I
                Customer Service for its subscribers, and shall credit
                DirectBill Subscribers with the amount of any charge for
                Information Services, which is disputed by the DirectBill
                Subscriber.

          3.4   Cingular through its billing vendor shall remit to Customer the
                amount collected from DirectBill Subscribers after subtracting
                customer credits, bad debt, applicable taxes as directed by
                Customer, and Cingular's Billing Fees.

          3.5   Cingular will from time to time, in its sole and absolute
                discretion, assess the reliability and trustworthiness of
                Customer, and the utility, appropriateness, and desirability, of
                Customer's Information Services. Based on Cingular's

                                        2

<PAGE>

                assessment of Customer and Customer's Information Services,
                Cingular shall determine whether to continue this Agreement. If
                Cingular determines in it sole and absolute discretion based on
                Cingular's assessment of Customer and Customer's Information
                Services that this Agreement should be terminated, Cingular
                shall give Customer thirty (30) days prior notice of the
                effective date of such termination. Notwithstanding the
                foregoing, if Cingular at any time determines that that
                Customer's Information Services or any part of them are
                Unsuitable Information Services, Cingular may suspend the
                performance of this Agreement immediately and without notice
                until and unless the Unsuitable Information Services are
                removed.

          4.    CUSTOMER UNDERTAKING AND REPRESENTATIONS

          4.1   Customer must develop its Information Services and host them in
                such a way that Cingular and Qpass can retrieve and deliver them
                to DirectBill Subscribers initiating a purchase request. A
                description of the programming necessary to integrate Customer's
                Information Services with Cingular's billing vendor is in the
                DirectBill QuickStart Guide which will be provided to Customer
                upon execution of this agreement, and can be found at
                alliances.cingular.com. This guide is subject to revision at any
                time with reasonable notification to Customer.

          4.2   Customer is solely responsible for the development, operation
                and maintenance of the Information Service and its sites.
                Customer also is responsible for ensuring that the Information
                Services (i) do not disparage, defame, or discredit Cingular or
                a Cingular Affiliate or their respective names and are not
                derogatory or detrimental to the good name or business
                reputation of Cingular or a Cingular Affiliate, and (ii) do not
                constitute Unsuitable Information Services. Cingular may
                immediately remove links to any Customer Content that violates
                the foregoing.

          4.3   Customer will be responsible for Tier II Customer Service as
                shown in Exhibit 2 ("Customer Service") of this agreement.

          4.4   Customer represents and warrants that the Information Service to
                be provided by Customer hereunder is in no way unlawful,
                harmful, threatening, defamatory, obscene, harassing, or
                racially, ethically or otherwise objectionable; that it does not
                facilitate illegal activity, depict sexually explicit images,
                promote violence, promote discrimination, promote illegal
                activities, or incorporate any materials that infringe or assist
                others to infringe on any copyright, trademark, or other
                intellectual property rights.

          4.5   Customer shall advise Cingular's billing vendor, Qpass Inc. of
                the amount of any sales, use, or other taxes that should be
                imposed on the charges for Customer's Information Services and
                shall cause Qpass to bill any such taxes and then either to
                remit such taxes to the appropriate authority or to deliver the
                amount of such taxes to Customer to pay to the appropriate
                authority. Customer agrees that Cingular is merely acting as a
                billing conduit for the amount of the charges imposed by
                Customer for its services and has not and will not provide
                Customer with any advice regarding the proper

                                        3

<PAGE>

                amount of any taxes that Customer should collect, or the
                jurisdictions to which such taxes should be remitted.

          4.6   Reporting: Customer shall report to Cingular on a quarterly
                basis its content roadmap outlining any upcoming Information
                Services to be launched. Additionally, Customer will report to
                Cingular on the tenth business day of each month the following
                transactional information-

                    -    Number of SMS (Short Message Service) messages sent to
                         the Cingular network
                    -    Number of Information Services sold through the
                         Cingular network using the Cingular Direct Bill (CDB)
                    -    Number of Information Services sold through the
                         Cingular network using other payment means
                    -    Number of good sent for free through the Cingular
                         network.

                    5.  FEES/PAYMENT SCHEDULE. Cingular shall receive from
                COMPANY as a fee for its Billing and Collection Services, the
                amounts shown on Exhibit 3 ("Revenue Share"). Additionally, the
                payment schedule by which fees will be received by the Customer
                is also shown in Exhibit 3.

                    6.  CINGULAR DIRECTBILL MARKETING REPRESENTATION. Customer
                must represent Cingular DirectBill in accordance with Cingular
                marketing standards, available via www.cingularads.com. Customer
                is permitted to utilize the Cingular logo as described therein,
                but must, at a minimum, include the text "Cingular DirectBill"
                as an option for payment via whatever payment authorization
                mechanism is utilized for the DirectBill-enabled applications
                listed in Exhibit 2.

                    7.  TERM/TERMINATION. The Initial Term of this Agreement
                shall be for one year from signature by both parties. The
                Agreement will automatically be extended, without any further
                action by either party, for additional consecutive periods of
                one (1) year each (each a "Renewal Period") unless notice of
                termination, as referenced in Section 3.5, is sent by Cingular.

                    8.  WARRANTY DISCLAIMER. THE WARRANTIES SET FORTH IN THIS
                AGREEMENT CONSTITUTE THE ONLY WARRANTIES MADE WITH RESPECT TO
                THE PERFORMANCE OF SERVICES PROVIDED UNDER THIS AGREEMENT. BOTH
                PARTIES SPECIFICALLY DISCLAIM ALL OTHER WARRANTIES, WRITTEN OR
                ORAL, STATUTORY, EXPRESS OR IMPLIED, INCLUDING WITHOUT
                LIMITATION ANY WARRANTY OF CONTENT PROVIDERABILITY, FITNESS FOR
                A PARTICULAR PURPOSE OR WARRANTIES ARISING FROM A COURSE OF
                DEALING, TRADE USAGE OR TRADE PRACTICE. IN ADDITION, NEITHER
                PARTY MAKES ANY WARRANTIES WHATSOEVER TO ANY PERSON OR ENTITY
                (INCLUDING BUT NOT LIMITED TO END USERS) OTHER THAN TO THE OTHER
                PARTY HEREUNDER.

          9.    LIMITATION OF LIABILITY

                                        4

<PAGE>

          9.1   General Limitations. IN NO EVENT SHALL EITHER PARTY BE LIABLE TO
                THE OTHER FOR INDIRECT, CONSEQUENTIAL, SPECIAL, INCIDENTAL,
                PUNITIVE OR EXEMPLARY DAMAGES, LOST PROFITS OR BUSINESS, OR
                COSTS OF REPLACEMENT SERVICES AND/OR DELAY, HOWEVER CAUSED AND
                ON ANY THEORY OF LIABILITY (INCLUDING CONTRACT, TORT, NEGLIGENCE
                OR STRICT LIABILITY), ARISING OUT OF THIS AGREEMENT. THESE
                LIMITATIONS SHALL APPLY EVEN IF A PARTY HAS BEEN ADVISED OF THE
                POSSIBILITY OF SUCH DAMAGES AND NOTWITHSTANDING ANY FAILURE OF
                ESSENTIAL PURPOSE OF ANY LIMITED REMEDY.

          9.2   Limitations on Direct Damages. IN THE EVENT OF ANY DAMAGES TO
                EITHER PARTY ARISING OUT OF THIS AGREEMENT, ANY RECOVERY OF
                DAMAGES BY THE OTHER PARTY SHALL NOT EXCEED THE AMOUNT PAID
                AND/OR OWED BY CUSTOMER IN THE TWELVE (12) MONTHS PRECEDING THE
                EVENT GIVING RISE TO DAMAGES. THE PARTIES ACKNOWLEDGE AND AGREE
                THAT THE FOREGOING AMOUNT IS NOT A PENALTY BUT REPRESENTS A GOOD
                FAITH ESTIMATE BY THE PARTIES OF THE AMOUNT OF DAMAGES INCURRED
                UPON BREACH OF THIS AGREEMENT. BOTH PARTIES ACKNOWLEDGE AND
                AGREE THAT THE AMOUNTS PAYABLE HEREUNDER SHALL APPLY, EVEN IF
                THE PAYING PARTY HAS BEEN ADVISED OF THE POSSIBILITY OF HIGHER
                AMOUNTS OF DAMAGES AND NOTWITHSTANDING ANY FAILURE OF ESSENTIAL
                PURPOSE OF ANY LIMITED REMEDY. THE LIMITATION SET FORTH IN THIS
                SUBSECTION SHALL NOT APPLY TO ANY AMOUNTS PAYABLE UNDER SECTION
                10 (INDEMNIFICATION) OF THIS AGREEMENT.

          10.   INFRINGEMENT AND INDEMNIFICATION.

          10.1      Customer represents and warrants that it has the right to
                license and deliver the Information Services to Cingular's
                subscribers within the United States, Canada and Mexico. To the
                knowledge of Customer, the Information Services are and will be
                free of any third party claims for misappropriation of trade
                secrets, or the infringement of any patent, copyright,
                trademark, service mark, or other proprietary right.

          10.2      Customer shall defend, indemnify and hold harmless Cingular,
                its affiliates and their respective present, former and future
                officers, directors, employees and agents, and their respective
                heirs, legal representatives, successors and assigns, and
                Cingular's vendor for billing services provided hereunder
                (collectively the "Cingular Indemnitees"), from and against any
                and all claims, actions, losses, costs, liabilities or expenses
                (including, without limitation, reasonable attorneys' fees)
                which any of the Cingular Indemnitees may suffer, incur or
                sustain resulting from, or arising out of (a) any breach of the
                representations and warranties in this Agreement; (b) any claim
                or action that Customer has misappropriated the trade secrets of
                a third person, or that any of the Information Services infringe
                any patent, copyright, trademark, service mark or other right of
                any third person; (c) any claim or action arising out of
                Customer' failure to obtain any consent, approval or license for
                the

                                        5

<PAGE>

                Information Services, or its failure to pay any fees in
                connection therewith; (d) violation by Customer of any
                applicable law, rule, or regulation without regard to source;
                (e) breach by Customer of any contract with a third party,
                including but not limited to agreements with End Users; (f) any
                material provided by Customer which is unlawful, libelous or
                defamatory; (g) any claim based on the merchantability, fitness
                for a particular purpose, or completeness, of the Information
                Services; or (h) any claim that Customers collection or use of
                End User personal information violates the privacy interests of
                any such End User.

          10.3      Customer shall, through counsel of its choice, reasonably
                acceptable to Cingular, assume the defense of any claim or
                action brought against any Cingular Indemnitee giving rise to
                the obligations and liabilities of Customer under this section,
                provided, however, that there is no conflict with such counsel's
                representation of both Cingular and Customer in connection
                therewith. Customer acknowledges and agrees that Cingular's
                vendor for billing services provided hereunder is a third party
                beneficiary of this provision.

          11.   NONDISCLOSURE.

          11.1      During the term of this Agreement it may be necessary for
                Cingular to provide Customer with certain written, electronic or
                oral information ("Information") considered to be private or
                proprietary. The Customer shall protect such Information
                received by it from whatever source from distribution,
                disclosure or dissemination or use to or by anyone except
                employees of Customer with a need to know such Information in
                conjunction with the provision of services hereunder, except as
                authorized herein or as otherwise authorized in writing.

          11.2      Customer will not have an obligation to protect any portion
                of Cingular's Information which:

          11.2.1    is made publicly available by Cingular or lawfully by a
                nonparty to this Agreement; or

          11.2.2    is lawfully obtained by Customer from any source other than
                Cingular; or

          11.2.3    is previously known to Customer without an obligation to
                keep it confidential; or

          11.2.4    is released by Cingular in writing.

          11.3      Customer will only make copies of the Information received
                from Cingular as are necessary for its use under the terms
                hereof, and each such copy will be marked with the same
                proprietary notices as appear on the originals. Customer agrees
                to use the Information solely in connection with this Agreement
                and for no other purpose. Customer agrees to return all
                Information and any copies thereof to Cingular upon termination
                of this Agreement. Customer agrees not to identify Cingular or
                any other owner of

                                        6

<PAGE>

                Information disclosed hereunder in any advertising or publicity
                without the prior written permission of Cingular.

          11.4      Customer's obligations as to the Information shall continue
                for a period of two (2) years after the termination of this
                Agreement, provided, however, that such obligation shall
                continue indefinitely as to Information constituting a Trade
                Secret under applicable law for so long as such Information
                remains a Trade Secret.

          12.   ARBITRATION.

          12.1      Cingular and Customer shall use their best efforts to settle
                any dispute or claim arising from or relating to this Agreement.
                To accomplish this, they shall negotiate with each other in good
                faith. If Cingular and Customer do not reach agreement within 30
                days, instead of suing in court, Cingular and Customer agree to
                arbitrate any and all disputes and claims (including but not
                limited to claims based on or arising from an alleged tort)
                arising out of or relating to this agreement, or to any prior
                agreement between Customer and Cingular or any of Customer's or
                Cingular's affiliates or predecessors in interest.

          12.2      The arbitration of any dispute or claim shall be conducted
                in accordance with the Wireless Industry Arbitration Rules ("WIA
                Rules") as modified by this Agreement and as administered by the
                American Arbitration Association ("AAA").

          12.3      Cingular and Customer acknowledge that this Agreement
                evidences a transaction in interstate commerce and that the
                United States Arbitration Act and Federal Arbitration law shall
                govern the interpretation and enforcement of, and proceedings
                pursuant to, this or a prior Agreement.

          12.4      Unless Cingular and Customer agree otherwise, the location
                of any arbitration shall be in Atlanta, Georgia.

          12.5      Cingular and Customer agree that no arbitrator has the
                authority to: (1) award relief in excess of what this or a prior
                agreement provides; (2) award punitive damages or any other
                damages not measured by the prevailing party's actual damages;
                or (3) order consolidation or class arbitration.

          12.6      Except as otherwise provided herein, all fees and expenses
                of the arbitration shall equally borne by Customer and Cingular.

          12.7      The arbitrator(s) must give effect to the limitations on
                Cingular's liability as set forth in this or a prior Agreement,
                any applicable tariff, law, or regulation.

          12.8      In any arbitration utilizing the rules applicable to
                Large/Complex cases, as defined under the WIA rules, the
                arbitrators must also apply the Federal Rules of Evidence, and
                the losing party may have the award reviewed in accordance with
                the review procedures set forth in the WIA rules.

                                        7

<PAGE>

          12.9      Customer agrees that Cingular and Customer each is waiving
                its respective right to a trial by jury, Customer acknowledges
                that arbitration is final and binding and subject to only very
                limited review by a court. If for some reason this arbitration
                clause is at some point deemed inapplicable or invalid, Customer
                and Cingular agree to waive, to the fullest extent allowed by
                law, any trial by jury, in such case, a judge shall decide the
                subject dispute or claim.

          12.10     Cingular, Customer and Arbitrator(s) shall not disclose the
                existence, content, or results of any arbitration. Judgement on
                the award rendered by the arbitrator(s) may be entered in any
                court having jurisdiction thereof.

          13.   Miscellaneous.

          13.1      The parties acknowledge that the relationship of the parties
                is that of independent contractors, and that nothing contained
                in this Agreement shall be construed to place the parties in the
                relationship of principal and agent, master and servant,
                partners or joint venturers. Neither party shall have, expressly
                or by implication, or represent itself as having, any authority
                to make contracts or enter into any agreements in the name of
                the other party, or to obligate or bind the other party in any
                manner whatsoever.

          13.2      The validity and effect of this Agreement shall be governed
                by and construed and enforced in accordance with the laws of the
                State of Georgia, without regard to its rules regarding
                conflicts of law.

          13.3      The headings as to contents of particular sections are
                inserted only for convenience and are in no way to be construed
                as part of this Agreement.

          13.4      Customer shall not issue or release for publication any
                articles or advertising or publicity matter relating to the work
                performed hereunder or mentioning or implying the name of
                Cingular or any Affiliate, or any of their personnel, unless
                prior written consent is granted by Cingular.

          13.5      Except as otherwise expressly provided in this Agreement,
                all notices and demands required or contemplated hereunder by
                one party to the other shall be in writing and shall be deemed
                to have been duly made and given upon date of delivery if
                delivered in person or by an overnight delivery or postal
                service, upon receipt if delivered by facsimile the receipt of
                which is confirmed by the recipient, or upon the expiration of
                five days after the date of posting if mailed by certified mail,
                postage prepaid, to the addresses or facsimile numbers set forth
                below their signatures. Either party may change its address or
                facsimile number for the purpose of this Agreement by notice in
                writing to the other party as provided herein.

          13.6      No failure or delay on the part of any party hereto to
                exercise any right or remedy hereunder shall operate as a waiver
                thereof, nor shall any single or partial exercise of any right
                or remedy by any party preclude any other or further exercise
                thereof or the exercise of any other right or remedy. No express
                waiver or assent by any party hereto to any breach of or default
                in

                                        8

<PAGE>

                any term or condition of this Agreement shall constitute a
                waiver of or an assent to any succeeding breach of or default in
                the same or any other term or condition hereof.

          13.7      The parties acknowledge that this Agreement has been entered
                into due to, among other things, the special skills and
                technical expertise of Customer, and agree that this Agreement
                may not be voluntarily or involuntarily assigned or transferred
                by Customer, in whole or in part, and none of the obligations of
                Customer under this Agreement may be delegated by Customer, in
                whole or in part, without the prior written consent of Cingular.

          13.8      This Agreement and the exhibits hereto constitute the entire
                agreement between the parties with respect to the subject matter
                hereof, and may not be amended except in writing signed by both
                parties.

                    IN WITNESS WHEREOF, the parties have caused this Agreement
to be executed by their duly authorized representatives, on the last date and
year noted below.

--------------------------------------------------------------------------------
CINGULAR WIRELESS LLC                     'CUSTOMER'

Signature:  /s/ Rob Hyatt                 Signature:  /s/ Rick Hennessey
          ----------------------------              ----------------------------
Name:  Rob Hyatt                          Name:  Rick Hennessey
     ---------------------------------         ---------------------------------
Title: Exec. Dir. - Data Product Mgt.     Title: President
      --------------------------------          --------------------------------
Date:  1-9-2004                           Date:  12-22-03
--------------------------------------    --------------------------------------

 Glenridge Highlands Two
 5565 Glenridge Connector                 Address: 5847 San Felipe St., Suite
 Atlanta, GA 30342                        2825
                                          Houston, Texas 77057-3000

Attn: Cristy Swink Director -             Attn: Robert E. Huntley
      3/rd/ Party Revenue                 Facsimile: (713) 924-9688
Facsimile: (404) 236-5430

With a copy to:                           With a copy to:

Glenridge Highlands Two                   Robert M. Mullins
5565 Glenridge Connector                  Gunn. Mullins & Farrell, L.L.P.
Atlanta, GA 30342                         1415 North Loop West, Suite 1100
Attn: General Counsel                     Houston, TX 77008
Facsimile:_________________               Facsimile: (713) 869-3085
--------------------------------------------------------------------------------

                                        9

<PAGE>

                                    Exhibit 1

                          Approved Information Services
                          -----------------------------

Content-
Customer will be allowed to sell Information Services to the Cingular User base.
This content will be limited to Java Games/Application, WAP Games, and
Ringtones, to any and all devices capable of receiving them. Cingular must be
notified, in advance of starting sales, of any other content categories outside
of these. Cingular will have thirty (30) days to respond to these requests and
disapprove the selling of these new content categories; else Customer can begin
sales efforts. Notification should be sent to the same address c/o the contract
signor for Cingular.

The initial content provided by the Customer will include the following:

--------------------------------------------------------------------------------
Content Type                  Titles
--------------------------------------------------------------------------------
-  Java (J2ME)                -  Star Exceed
                              -  Star Diversion
                              -  Dwango Racing
                              -  Aqua X
                              -  Jumpeon
                              -  Blackjack
                              -  Roulette
                              -  Slots
                              -  Etc.
-  WAP Games                  -  Traders Odyssey
                              -
                              -
-  Ringtones                  -
                              -
                              -
-                             -
                              -
                              -
--------------------------------------------------------------------------------

                                       10

<PAGE>

                                    Exhibit 2
                                    ---------

                                Customer Service

Customer shall provide the following customer support to Cingular. Cingular
shall be responsible for billing related customer service contact with Users
(Tier I). Any technical problem found during the use of Information Services may
be identified and with best efforts classified and shared with the Customer by
Cingular.

(1)  Customer shall create and provide to Cingular one set of support training
     materials, in the English language, for use by Cingular as a reference when
     reviewing customer issues and potential inquiries regarding Information
     Services.

(2)  Suspected Technical Problem With Content:
     (a)  If Cingular suspects a technical problem with any Information Service
          (a "Suspected Technical Problem") for which Customer may be
          responsible hereunder, Cingular shall direct such Suspected Technical
          Problem in English to Customer via identified appropriate contact
          identified in Section 1.3. (the "Suspected Technical Problem Notice").
     (b)  The Suspected Technical Problem Notice shall be directed as
          appropriate (likely via toll-free customer service phone number or
          email) and shall attempt to include the following information:
          (i)   Contact information of the reporter/reporting department
                (including name, department, call back number, fax number and
                email address);
          (ii)  The Information Service affected (Cingular shall identify the
                Information Service in accordance with the file name utilized by
                Customer to deliver same to Cingular);
          (iii) Description of Suspected Technical Problem including, without
                limitation, the nature of the malfunction or design defect;
          (iv)  An issue severity level; and
          (v)   Any other pertinent information to assist Customer in its
                analysis and proposed resolution of the Suspected Technical
                Problem.
     (c)  Response to a Suspected Technical Problem Notice.
          (i)   Customer shall use commercially reasonable efforts to resolve
                the Suspected Technical Problem as quickly as possible.
          (ii)  Customer will communicate efforts, solution results, or listing
                of continued issues to Cingular as a part of this response.
(4)  Technical Questions.
     (a)  If Cingular has a technical question regarding Information Services in
          the event there is no Suspected Technical Problem (a "Technical
          Question"), Cingular may direct such Technical Questions, in English,
          to appropriate contact point as identified in Section 1.3 ("Technical
          Question Notice").
     (b)  The Technical Question Notice shall contain the following information:
          (i)   Contact information of the reporter/reporting department
                (including name, department, call back number, fax number and
                email address);
          (ii)  The Information Service affected (Cingular shall identify the
                Information Service in accordance with the file name utilized by
                Customer to deliver same to Cingular);

                                       11

<PAGE>

          (iii) Description of the Technical Question, including, without
                limitation, questions concerning functionality of the
                Information Service and/or Java content or questions concerning
                documentation provided to Cingular;
          (iv)  Any other pertinent information to assist Customer in its
                analysis and proposed resolution of the Suspected Technical
                Problem.
     (c)  Response to a Technical Question Notice.
          (i)   Customer shall use commercially reasonable efforts to respond to
                a Technical Question Notice within five (5) Business Days after
                its receipt.
          (ii)  Customer's response to a Technical Question Notice shall include
                any applicable answers or solutions to the Technical Question.

                                       12

<PAGE>

                                    Exhibit 3

                                  Revenue Share

Revenue Share-
Customer will receive [*] of all revenues associated with sale of
Information Services to the Cingular customers. Cingular will retain the
remaining [*] of such revenue when the Customer used Cingular Direct
Bill (CDB) for payment of Information Services. Customer will be required to
offer CDB as the primary billing solution for the sale of Information Services.

Cost
Customer will pay $400 to Cingular for Direct Bill vendor setup costs. This
amount is payable within 10 business days following the receipt of the executed
copy of this agreement. Checks should be made payable to Cingular Wireless and
sent to the address as noted in this agreement.

Retail Pricing-
Customer will have sole discretion to determine the retail pricing however, all
transactions will be priced at a minimum of $1.00 USD when using CDB as a
payment option.

Payment Schedule-
Cingular, through its billing vendor, shall pay Customer on thirty day (monthly)
cycle within 45 days after Cingular receipt and confirmation of invoice from
Cingular's billing services vendor (QPass) (e.g. April billing cycle potentially
received by Cingular on May 5/th/, confirmed on May 10/th/, payment sent by
Cingular by approximately June 15/th/.)

----------------
*  Certain information on this page has been omitted and filed separately with
   the Securities and Exchange Commission. Confidential treatment has been
   requested with respect to the omitted portions.

                                       13

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00065-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00065-of-00352.parquet"}]]