Document:

Second Amended and Restated Wireless Services Agreement #00014249

 Exhibit 10.2 

Second Amended and Restated Wireless Services Agreement 

#00014249 

between 

InfoSpace Mobile, Inc. 

and 
 Cingular
Wireless LLC 
 Agreement No: 00014249 

Effective Date: July 22, 2005 

 Table of Contents 

 

					
	 Section
	  	Page
			
	1.	 	Definitions	  	1
			
	2.	 	Certain Rights Granted	  	4
			
	3.	 	Certain Obligations of the Parties	  	6
			
	4.	 	Hosting	  	9
			
	5.	 	Payments	  	9
			
	6.	 	Warranties, Indemnification and Limitation of Direct Liability	  	10
			
	7.	 	Term and Termination	  	15
			
	8.	 	Intellectual Property	  	16
			
	9.	 	General Provisions	  	17
		
	Exhibits	  	
			
	A.	 	Services	  	24
			
	B.	 	Trademarks	  	41
			
	C.	 	Commercial Terms	  	43
			
	D.	 	Change Request Process & Acceptance Test Process	  	46
			
	E.	 	Executive Orders and Federal Regulations	  	50
			
	F.	 	Attribution	  	53
			
	G.	 	Service Level Agreement	  	56
			
	H.	 	Business Requirements Template	  	86
			
	I.	 	Change Request Template	  	101
			
	J.	 	Work Order and Purchase Order Template	  	103
			
	K.	 	License Agreement	  	105
			
	L.	 	Cingular Customized Work Product	  	148
			
	M.	 	Security Requirements for System or Network Access by Contractors	  	149

  

 2 

 Second Amended and Restated Wireless Services Agreement #00014249 

This Second Amended and Restated Wireless Services Agreement, effective as of, July 22, 2005 (the
“Effective Date”), is made by and between InfoSpace Mobile, Inc., a California corporation and a wholly owned subsidiary of InfoSpace, Inc., with principal offices at 10940 Wilshire Blvd.,
9th Floor, Los Angeles, CA 90024
(“InfoSpace”), Cingular Wireless LLC, a Delaware limited liability company on behalf of itself and its Affiliates (“Cingular”), with principal offices at 5565 Glenridge Connector, Atlanta, Georgia 30342, and, solely
with respect to Section 9.12, InfoSpace, Inc., a Delaware corporation, with principal offices at 601
108th Ave., Suite 1200, Bellevue, WA 98004. 

RECITALS 
 This Agreement
is entered into with reference to the following facts: 
  

	 	A.	Cingular and InfoSpace, Inc., the parent company of InfoSpace Mobile, Inc., entered into that certain Amended and Restated Wireless Services Agreement #00014249,
effective as of July 1, 2003 (as amended, the “Prior Agreement”). 

  

	 	B.	The parties desire to amend and restate the Prior Agreement, as more fully described below. This Second Amended and Restated Wireless Services Agreement (together with
all exhibits hereto and as amended in writing from time to time, this “Agreement”) shall replace in its entirety the Prior Agreement as of the Effective Date. 

AGREEMENT 
 The parties
agree as follows: 
  

	1.	Definitions. 

 As used
herein, the following terms have the following defined meanings: 
 “Active User” means a User for whom
InfoSpace reports three or more Sessions during a calendar month of the Term. 
 “Administrator” means a
Cingular employee designated by Cingular to access the Management Console (as defined in Section B (1) of Exhibit A). 

“Affiliate” means an entity that has its principal place of business in the United States or Puerto Rico and that
directly or indirectly, through one or more intermediaries, controls, is controlled by or is under common control with another entity. Control shall be defined as (i) thirty percent (30%) or more ownership or beneficial interest of income
and capital of such entity; (ii) ownership of at least thirty percent (30%) of the voting power or voting equity; or (iii) the exclusive or shared ability to otherwise direct the management policies of such entity by contract or
otherwise. 
 “Agreement” means this Second Amended and Restated Wireless Services Agreement
#00014249, including all exhibits hereto. 
 “Cingular Customized Work Product” means the deliverables described
in Exhibit L that InfoSpace will develop and deliver to Cingular in accordance with Section 8.3. 
  

 1 

 “Cingular Marks” means those Trademarks of Cingular set forth on Exhibit B
hereto and such other Trademarks (if any) as Cingular may from time to time notify InfoSpace in writing to be “Cingular Marks” within the meaning of this Agreement. 

“Cingular Materials” means the Cingular Customized Work Product, Cingular Marks, Cingular Sourced Content, and any other
materials provided by Cingular to InfoSpace. Cingular may, from time to time, add, modify, or delete any or all Cingular Materials upon written notice to InfoSpace. InfoSpace shall use commercially reasonable efforts to add, modify or delete such
Cingular Materials within the timeframe requested by Cingular or as otherwise agreed by the parties. 
 “Cingular
Network” means the equipment and systems that are owned, operated and/or managed by Cingular for the provision of the Services to Users. 

“Cingular Sourced Content” has the meaning set forth in Exhibit A. 

“Co-branded Pages” means, collectively, the Mobile Pages and PC Pages hosted on the InfoSpace Web Sites that comprise a
portion of the Services. 
 “Content” means the InfoSpace Sourced Content and the Cingular Sourced Content.

 “Feature Acceptance Date” has the meaning set forth in Exhibit D. 

“InfoSpace Marks” means those Trademarks of InfoSpace set forth at
http://www.infospaceinc.com/about/legal_trademarks.php, which may be modified and updated by InfoSpace from time to time. 

“InfoSpace Software” means the software owned by InfoSpace that is used by InfoSpace to host the Services. 

“InfoSpace Sourced Content” has the meaning set forth in Exhibit A. 

“InfoSpace Supported Handsets” means the Wireless Devices set forth in Section C of Exhibit A through which InfoSpace
shall make the Services available. 
 “InfoSpace Web Sites” means, collectively: (a) the Web Site the
primary home page of which is located at http://www.infospace.com; and (b) other Web Sites maintained by InfoSpace and its affiliates. 

“Intellectual Property Rights” means any patent, copyright, rights in Trademarks, trade secret rights, and other
intellectual property or proprietary rights arising under the laws of any jurisdiction. 
 “License Agreement”
means the license agreement attached hereto as Exhibit K that the parties may enter pursuant to Section 4(b) or Section 7.2 of this Agreement. The License Agreement contains the terms and conditions pursuant to which InfoSpace will
license the InfoSpace Software to Cingular. This License Agreement applies only to the InfoSpace Software that is listed on Exhibit B to the License Agreement and not the Cingular Customized Work Product. 

“Mobile Pages” means web pages that are prepared using Wireless Markup Language (WML) and Extensible Hypertext Markup
Language (XHTML) for mobile devices (as described in Exhibit A), and intended for presentation to Users using InfoSpace Supported Handsets. 
  

 2 

 “PC Pages” means web pages that are prepared using Hypertext Markup
Language (as described in Exhibit A), and intended for presentation to Users using a Personal Computer as their terminal/display device. 

“Person” means any natural person, corporation, partnership, Limited Liability Company or other entity. 

“Portal User” means each unique profile for a Person who at any time has used the Services (which profile may be derived
from information or a combination of information that may include, but is not limited to, screen name, device identifier and/or MSISDN). 

“Services” means the Technology, products, applications and services (and all modifications, upgrades and revisions
thereto) that will be made available to Cingular by InfoSpace pursuant to this Agreement, as more particularly described on Exhibit A. 

“Service Level Agreement” (SLA) means the Service Level Agreement by and between InfoSpace and Cingular, entered into on
the date hereof and made a part hereof for all purposes, and attached hereto as Exhibit G. 
 “Session” means
any use of the Services by a User during any thirty minute period.  
 “SMS Message” means a message sent
or received by InfoSpace via a push (MT SMS) or pull (MO SMS) service using short text codes, including a message containing an embedded link to a WAP page. 

“Technology” means any technical, functional and architectural specifications authored by InfoSpace, or any know-how,
graphics, techniques, methods, formulae, drawings, designs, source code, concepts, ideas, documentation, or any improvement or upgrade thereto, whether or not patentable or copyrightable and whether or not reduced to practice, owned or licensed by
or on behalf of InfoSpace or any of its Affiliates to create, provide, use, modify, adapt, publish, display, update, enhance, improve or maintain the Services or any portion thereof or to provide access to any of the Content or Services; except,
however, “Technology” does not include the Cingular Materials. 
 “Term” has the meaning set forth in
Section 7.1. 
 “Trademarks” means any trademarks, service marks, trade dress, trade names, corporate names,
proprietary logos or indicia and other source or business identifiers. 
 “User Data” has the meaning set forth
in Section 3.11(a). 
 “Web Site” means any point of presence maintained on the Internet or on any other
public data network accessed via any portable or non-portable computing device. With respect to any Web Site maintained on the World Wide Web, such Web Site includes all HTML, XHTML or WML pages (or similar unit of information presented in any
relevant data protocol) that either are identified by the same second-level domain (such as infospace.com) or by the same equivalent level identifier in any relevant address scheme. 

“Wireless Device” means cellular phones, personal digital assistants, pagers and RIM devices. 

“User” means any Person that is authorized by Cingular to access the Services. 

Any capitalized term used in this Agreement but not defined in this Section 1 shall have the meaning ascribed to such term in this Agreement.

  

 3 

	2.	Certain Rights Granted. 

2.1 InfoSpace Grant. Subject to the terms and conditions of this Agreement and during the Term (as defined in
Section 7.1), InfoSpace will make available to Cingular the Services described in Exhibit A and hereby grants to Cingular the right to enable Users and up to 500 employees of Cingular, collectively, to access the available Services through PCs
(for PC Pages) and on InfoSpace Supported Handsets via the Cingular Network (for Mobile Pages), as described in Exhibit A. 

2.2 Cingular Grant. Subject to the terms and conditions of this Agreement, Cingular hereby grants to InfoSpace the right to
include the Cingular Materials on the Services. 
 2.3 Limitations. 

 

	 	(a)	Cingular shall have no right by virtue of this Agreement to reproduce or sub-license, re-sell or otherwise distribute all or any portion of the Content or Services
under this Agreement to any Person, other than providing access to the Content and Services to Users. 

  

	 	(b)	Each party acknowledges that the rights granted by the other party hereunder are subject to the rights of certain third parties. Neither party shall be required to
deliver Content in violation of any law of any jurisdiction. If delivery of Content under this Agreement is deemed to be in violation of any law, the providing party shall provide three (3) business days notice to the other party, and
InfoSpace, to the extent reasonably possible, shall remove or modify such Content If, in the sole discretion of Cingular, such removal or modification would materially alter the Content or the Services, the parties agree to negotiate amended terms
with respect to such Content or Services in good faith. 

  

	 	(c)	Cingular shall reasonably allow InfoSpace and its Affiliates to implement, or Cingular shall otherwise reasonably cooperate with InfoSpace and its Affiliates, upon
their written request, for the purpose of the implementation of, any bug fixes and/or updates for any Services or Content access supplied hereunder. 

  

	 	(d)	Unless expressly authorized by the other party in writing, or unless otherwise specifically provided in this Agreement, neither Cingular nor InfoSpace shall itself, nor
shall either authorize or assist any third party to, (a) remove, obscure, or alter any legal notices, including notices of Intellectual Property Rights present on or in the Content or Services provided hereunder or any other materials provided
by the other party, or (b) “frame” the Content or insert any advertisements (including interstitial advertisements), pop-up windows, new consoles or other items, or use any other techniques, that would alter the appearance or
presentation of the Services, or any of the InfoSpace Web Sites, from that seen by users hand-entering the applicable URL into their browser. 

  

	 	(e)	Other than in connection with their performance under this Agreement, InfoSpace and its Affiliates shall have no right under this Agreement to reproduce or sub-license,
re-sell or otherwise distribute all or any portion of the Cingular Materials to any Person. 

  

	 	(f)	Cingular will not reverse engineer, disassemble, decompile or otherwise attempt to discover the source code or trade secrets for any of the Technology or the Services,
except that this restriction shall not apply to any Cingular Materials. 

  

 4 

	 	(g)	To the extent that it is within InfoSpace’s reasonable control, InfoSpace will promptly remove, upon Cingular’s written request, the display of pornographic
or “adult” graphics, text and other material, on the Services. In the event of disagreement over whether the materials constitute pornographic or adult graphics, text or other material, Cingular’s opinion shall prevail.

  

	 	(h)	InfoSpace shall not allow access, nor grant any right to enable access, to the available Content or Cingular Materials on the Services, other than the access granted in
Section 2, or as otherwise agreed, in writing, by the parties. 

  

	 	(i)	InfoSpace will not implement any new, or modify any existing, Content on the Services without prior written approval by Cingular. 

 

	 	(j)	In the event that InfoSpace or any of its Affiliates receives an offer from a third party content provider to pay InfoSpace for the distribution, use or placement of
content to or with Cingular or any Users as part of the Services, then InfoSpace shall promptly notify Cingular of such offer and provide the details thereof to Cingular. If InfoSpace accepts such offer without the prior written approval of
Cingular, then InfoSpace shall pay to Cingular all monies or other consideration received from such agreement within 10 business days of InfoSpace’s receipt of same. 

2.4 Cingular Marks License. Subject to Section 2.6 and the conditions set forth in this Section 2.4, Cingular hereby
grants to InfoSpace and its affiliates the right to use, reproduce, publish, perform and display the Cingular Marks: (a) on the InfoSpace Web Sites in connection with the posting of hyperlinks to the Services; (b) with the prior written
approval of Cingular in connection with the development, use, reproduction, modification, adaptation, publication, display and performance of the Services; and (c) with the prior written approval of Cingular and subject to the provisions of
this Agreement relating to publicity, in promotional and marketing materials, content directories and indices, electronic and printed advertising, publicity, newsletters and mailings about InfoSpace and its affiliates and their relationship with
Cingular and the Services. 
 2.5 InfoSpace Marks License. Subject to Section 2.6, InfoSpace hereby grants to
Cingular the right to use, reproduce, publish, perform and display the InfoSpace Marks: (a) on the Services in connection with the posting of hyperlinks to the Content; and (b) with the prior written approval of InfoSpace and subject to
the provisions of this Agreement relating to publicity, in and in connection with the development, use, reproduction in promotional and marketing materials, content directories and indices, and electronic and printed advertising, publicity,
newsletters and mailings about Cingular and its relationship with InfoSpace and its affiliates and the Services. 
 2.6 Use of
Trademarks. Prior to the first use of any of the other party’s Trademarks in the manner permitted herein, the party using such Trademarks shall submit a sample of such proposed use to the other party for its prior written approval. Without
limiting the generality of the foregoing, each party shall strictly comply with all standards with respect to the other party’s Trademarks which may be furnished by such party from time to time, and all uses of the other party’s Trademarks
in proximity to the trade name, trademark, service name or service mark of any other person shall be consistent with the standards furnished by the other party from time to time. Further, neither party shall create a combination mark consisting of
one or more Trademarks of each party. All uses of the other party’s Trademarks shall inure to the benefit of the party owning such Trademark. InfoSpace hereby acknowledges and agrees that, as between the parties hereto, Cingular is the owner of
the Cingular Marks. Cingular hereby acknowledges and agrees that, as between the parties, InfoSpace is the owner of the InfoSpace Marks. Either party may update or change the list of Trademarks usable by the other party hereunder at any time by
written notice to the other party. Upon expiration or termination of this Agreement, each party’s rights to use any of the other party’s Trademarks will terminate. 

 

 5 

 2.7 Non-exclusivity. The parties acknowledge and agree that this Agreement is
non-exclusive, and that, without limiting the generality of the foregoing, nothing in this Agreement shall be deemed or construed to prohibit either party from participating in similar business arrangements with any Person as those described herein.
InfoSpace understands that Cingular does not guarantee any number of Users who will have access to the Services; further, InfoSpace understands that Users may terminate any and all access to the Services, and, upon thirty (30) days’ prior
written notice to InfoSpace, Cingular may redirect Users to another Web Site, at any time during the Initial Term or any renewal term of this Agreement, provided that nothing in this Section 2.7 shall relieve Cingular of its obligations under
this Agreement, including its payment obligations pursuant to Exhibit C. 
  

	3.	Certain Obligations of the Parties. 

3.1 Services. Cingular and InfoSpace will cooperate to design, and InfoSpace will implement in accordance with Exhibit A, the
user-perceptible elements of the graphical user interface for the Services, with the goals of: (a) conforming the graphical user interface with branding, graphics, navigation, content or other characteristics or features of the display output
of the “look and feel” of the Services to that associated with the applicable existing Cingular Web Sites; (b) integrating content and commerce services from third parties according to terms of this Agreement; (c) maximizing the
commercial effectiveness thereof; and (d) optimizing the presentation of the relevant Content for access from mobile phones and devices. 

3.2 Cingular Obligations. Cingular shall integrate the acknowledgement “Powered by InfoSpace” and the InfoSpace logo on
all of the PC Pages in a mutually agreeable manner. “Powered by InfoSpace” or equivalent attribution shall appear at the bottom of a single prominent page of the Mobile Pages in a manner mutually agreeable to both parties. Cingular shall
also provide to InfoSpace and its Affiliates at its expense such cooperation and assistance as they reasonably request in connection with the development, use, reproduction, modification, adaptation, publication, display and performance of the
Services. Examples of the proportionate size and location of attribution on the PC Pages and Mobile Pages are set forth on Exhibit F. 

Notwithstanding the above, should Cingular choose to host this service with anyone other than InfoSpace, this section will no longer
apply. 
 3.3 Removal of Content. To the extent that it is within InfoSpace’s control, InfoSpace shall remove Content
specified by Cingular for removal from the Services upon Cingular’s written request. InfoSpace shall remove such Content within a reasonable timeframe not to exceed thirty (30) days of receipt of Cingular’s request or as otherwise
agreed by the parties. 
 3.4 Service Level Agreement. Attached as Exhibit G is a Service Level Agreement setting forth
the respective responsibilities of the parties regarding support of the Services. For so long as Cingular redirects all Users to another Web Site pursuant to Section 2.7, the Service Level Agreement will no longer apply. 

3.5 Technical Cooperation. Each party will provide reasonable technical cooperation to the other party in order to implement the
Services. In addition, Cingular shall allow InfoSpace to implement and/or cooperate with InfoSpace upon its request in its implementation of any bug fixes or updates to the Services. 

 

 6 

 3.6 Project Management. Each party will appoint a single primary point of contact for
project management and coordination. This individual will be responsible for coordinating internal teams and activities associated with the deployment of the Services; prioritizing issues and change requests; providing internal communication of
project schedule and status; and coordinating meetings and other joint activities between the parties. 
 3.7 Cingular
Network. During the Term, Cingular will maintain the Cingular Network and will provide Users with access to the Services via the Cingular Network. 

3.8 Publicity. The parties may work together to issue publicity and general marketing communications concerning their relationship
and other mutually agreed-upon matters, provided, however, that neither party shall have any obligation to do so. In addition, neither party shall issue any such publicity and general marketing communications concerning their relationship without
the prior written consent of the other party, which shall not be unreasonably withheld or delayed. 
 3.9 Future Services;
Work Orders. Unless otherwise agreed, the parties will use the process described in Exhibit D for all customizations, modifications, enhancements and additions to the Services. Unless otherwise agreed, the parties shall use the form attached
hereto as Exhibit J (a “Work Order”) to document all customizations and modifications to the Services. The Work Order shall set forth the work to be performed, the associated fees for such work, and any other applicable terms and
conditions. InfoSpace will perform the tasks set forth on each Work Order and will use commercially reasonable efforts to complete such tasks according to the estimated timeline (if any) set forth on each such Work Order. Cingular will cooperate
with InfoSpace and provide such assistance as InfoSpace may reasonably request to fulfill its obligations under each such Work Order. InfoSpace’s obligation to complete the tasks specified in each such Work Order by the corresponding dates (if
any) shall be subject to InfoSpace’s receipt from Cingular of all necessary Cingular Materials and/or technical specifications by the date set forth in each such Work Order for delivery of such materials, or if no date is set forth, by a date
to be mutually agreed by the parties. 
 Notwithstanding the above, no Work Order is authorized until InfoSpace is in receipt of
a Cingular issued Purchase Order, the form of which is attached hereto as Exhibit J (a “Purchase Order”). All Purchase Orders issued by Cingular hereunder shall include the corresponding Work Order as an attachment. If the terms of the
Purchase Order are materially different than the terms of the Work Order, InfoSpace may reject the Purchase Order. 
 All Work
Orders and Purchase Orders shall be made under and incorporate the terms and conditions of this Agreement. The terms and conditions referenced on the form of the Purchase Order shall not apply to any Purchase Order issued in connection with this
Agreement. 
 3.10 Other Requirements. InfoSpace and Cingular shall fulfill their respective obligations set forth in the
Exhibits. 
 3.11 Use and Protection of User Data. 

 

	 	(a)	User Data. To the extent that InfoSpace receives or has access to any personally-identifiable User data (including, but not limited to, customer proprietary
network information, profiles, User usage data and other data resulting from User use of the services) (collectively, “User Data”), Cingular retains all rights to, and is the sole owner of, all User Data. InfoSpace will treat all
User Data as Cingular Confidential Information pursuant to Section 9.4 of this Agreement. InfoSpace will not use or disseminate or authorize the use or dissemination of any User Data for any purpose other than in connection with the performance
of InfoSpace’s obligations under this Agreement, without Cingular’s advance written permission, which may be withheld in Cingular’s sole discretion. 

 

 7 

	 	(b)	Protection and Security of User Data. InfoSpace will not use or disclose, or permit others to use or disclose, any User Data except as necessary for InfoSpace to
fulfill its obligations under this Agreement, or otherwise in accordance with Cingular’s written instructions. InfoSpace will take all reasonable precautions to protect User Data against unauthorized disclosure or alteration, theft, or other
misuse including without limitation, maintaining and enforcing safety and security procedures and policies with respect to access, handling and maintenance of User Data reasonably designed to (i) insure the integrity and security of User Data;
(ii) protect against any reasonably foreseeable threats or hazards to the integrity or security of User Data; and (iii) protect against unauthorized access to or use of User Data that could result in substantial harm or inconvenience to
Cingular or Users. Further, the parties will cooperate with each other on an ongoing basis to evaluate security standards and will evaluate in good faith recommendations made by the other to protect the security and integrity of User Data.

  

	 	(c)	Retention of User Data. As soon as InfoSpace no longer needs to retain any item of User Data in order to perform its duties under this Agreement or otherwise
upon Cingular’s written request, InfoSpace will, at Cingular’s option, promptly return or destroy all tangible material embodying User Data in its possession or under its control. 

 

	 	(d)	Aggregate Information. Notwithstanding anything to the contrary in this Agreement, Cingular grants the right to InfoSpace to track and use Aggregate Information
(as defined below) about the Services, including usage patterns, transaction-related information, demographic data, and other aggregate User Data for the following purposes: statistical analysis, internal product analysis and development,
de-bugging, system maintenance purposes, the performance of its services and obligations under this Agreement, and for such other purposes as may be mutually agreed in writing by the parties from time to time. InfoSpace may also report such
Aggregate Information to certain third parties solely for purposes of (i) promoting InfoSpace and/or InfoSpace products and services in connection with marketing, investor relations and/or advertising-related activities, and (ii) complying
with InfoSpace’s contractual obligations to its third party content providers. For the purposes of this Agreement, “Aggregate Information” means User Data that does not specifically identify a User, Cingular, or any of
Cingular’s Affiliates, provided, that InfoSpace may identify Cingular in connection with its reporting to its third party content providers. 

  

	 	(e)	Computer Asset Protection Requirements. With respect to the Technology and InfoSpace Software, InfoSpace agrees to comply with Cingular’s Corporate Security
Standards Technical Reference (“CSSTR”) entitled “Security Requirements for Contractual Agreements” as set forth in Exhibit M. This reference fully incorporates Exhibit M herein. InfoSpace agrees to
cooperate fully with Cingular to ensure that the Technology, InfoSpace Software, and/or computer systems that InfoSpace uses to provide the Services under this Agreement comply with the Requirements set forth in Exhibit M. The word
“Contractor” used in Exhibit M shall mean InfoSpace. InfoSpace agrees that all of its personnel having access to Cingular’s systems will act in accordance with Exhibit M. 

 

 8 

	4.	Hosting. 

  

	 	(a)	InfoSpace will host the Services in a server environment dedicated to Cingular at one or more facilities maintained by or on behalf of InfoSpace or one of its
Affiliates. InfoSpace shall obtain, operate and maintain all hardware and software reasonably necessary to host the Services in connection with this Agreement. Upon receipt of a written request and authorization from Cingular, InfoSpace will
purchase hardware on Cingular’s behalf. Such hardware will be owned by Cingular. Upon termination of this Agreement, InfoSpace will deliver such hardware, or hardware with the same specifications, to Cingular. Cingular shall pay any fees or
other costs associated with such delivery and the transfer to Cingular of any service agreements related to such hardware. 

  

	 	(b)	After April 22, 2006, upon six months’ prior written notice to InfoSpace, InfoSpace shall allow Cingular to host the InfoSpace Software and make the Services
(excluding certain Legacy Services as described in Section B.1.b. of Exhibit A) available to Users at Cingular’s expense at one or more facilities maintained by or on behalf of Cingular or the facilities of a third party, unless within ten
business days of receipt of such notice InfoSpace has notified Cingular of its election to terminate this Agreement pursuant to Section 7.3. Cingular acknowledges that its ability to host the InfoSpace Software and make the Services available
to Users may be subject to Cingular’s ability to obtain sufficient rights in certain third party technology (e.g., any third party software used in connection with the hosting, operation and/or maintenance of the Services), content and
applications. In the event that Cingular elects to host the InfoSpace Software and InfoSpace has not elected to terminate this Agreement as described above, InfoSpace and Cingular shall enter into the License Agreement attached hereto as Exhibit K.
The term of the License Agreement entered into pursuant to this Section 4(b) shall be one (1) year. Cingular will not use the InfoSpace Software for any purpose other than to make the Services available to Users. The transition of hosting
will be performed by the parties in accordance with a schedule and commercial terms to be mutually agreed by the parties in a Work Order. 

  

	5.	Payments. 

 5.1 Fees
and Payments. Cingular shall pay to InfoSpace the fees set forth on Exhibit C in accordance with the terms and conditions of this Agreement and as set forth on Exhibit C. All payments to InfoSpace by Cingular shall be preceded by an invoice from
InfoSpace. Subject to section 5.2, Cingular shall pay InfoSpace in accordance with the amounts stated on any invoice delivered under this Agreement within forty-five (45) days of the date of the invoice. All payments from Cingular should
clearly show the corresponding invoice number. 
 5.2 Remuneration; Collection. Cingular shall pay to InfoSpace the
amounts as set forth on Exhibit C. Each party may accept any check or payment without prejudice to its rights to recover the balance due or to pursue any other right or remedy. No endorsement or statement on any check or payment or letter
accompanying any check or payment or elsewhere will be construed as an accord or satisfaction. Unless explicitly stated on Exhibit C, all amounts payable under this Agreement are denominated in United States dollars and each party will pay all
amounts payable under this Agreement in lawful 
  

 9 

 
money of the United States. In the event of a disputed amount on any invoice, the billed party shall notify the billing party of its dispute in writing within forty-five (45) days of receipt
of invoice, setting forth the reasons therefor. The billing party will respond within thirty (30) days of receipt of the billed party’s notice of dispute, at which time either (a) the billing party will agree with the claim and will
waive payment, or (b) the parties will agree to meet to resolve the dispute within a reasonable period of time. During this process, InfoSpace does NOT have the right to remove the Services (links, content, etc.). The non-prevailing party will
be responsible for all reasonable expenses (including attorney fees) incurred by the prevailing party in any action brought for the collection of past due amounts payable under this Agreement. 

5.3 Records and Audit. During the Term, each party shall maintain accurate records of fees received and calculations of the fees
payable to the other party pursuant to this Agreement. Either party, at its expense, and upon thirty (30) business days’ advance written notice to the other party, shall have the right to examine or audit such records in order to verify
the amounts owed to either party under this Agreement. Any such audit shall be conducted, to the extent possible, during normal business hours and in a manner that does not interfere with the ordinary business operations of the audited party.

  

	6.	Warranties, Indemnification and Limitation of Direct Liability. 

6.1 Warranties 
  

	 	(a)	Each party represents and warrants to the other party that: 

  

	 	1)	it has the full corporate right, power and authority to enter into this Agreement and to perform the acts required of it hereunder; its execution of this Agreement and
performance of its obligations hereunder, do not and will not violate, breach, or result in a default of any contract, lease, or other agreement to which it is a party or by which it is bound, any of which violations, breaches, or defaults could
reasonably be expected to have a material adverse effect on the ability of such party to perform its obligations hereunder; 

  

	 	2)	its execution of this Agreement and performance of its obligations hereunder, do not and will not violate or conflict with the articles of incorporation or by-laws (or
other governing instruments) of such party; 

  

	 	3)	when executed and delivered, this Agreement will constitute the legal, valid and binding obligation of such party, enforceable against it in accordance with its terms;
and 

  

	 	4)	it will comply with all then-current applicable laws, rules, and regulations in connection with the exercise of their rights and obligations under this Agreement
(including, without limitation, any related to individual privacy). 

  

	 	(b)	In addition to the foregoing, InfoSpace represents and warrants that, to its knowledge, there are no actions, suits, or proceedings, pending or threatened, which will
have a material adverse effect on InfoSpace’s ability to fulfill its obligations under this Agreement. 

  

	 	(c)	InfoSpace warrants to Cingular that the Services will be free from material defects in design, material and workmanship. 

 

	 	(d)	InfoSpace also warrants to Cingular that the Services provided hereunder will be performed in a professional manner, in material compliance with the specifications in
Exhibit A, and with the care, skill, and diligence, and in accordance with the applicable standards, currently recognized in InfoSpace’s profession or industry. 

 

 10 

	 	(e)	InfoSpace also warrants to Cingular that the Services performed by any of its representatives, including any subcontractor, will be performed in a professional manner,
in material compliance with the specifications in Exhibit A, and with the care, skill and diligence, and in accordance with the applicable standards, currently recognized in InfoSpace’s profession or industry. InfoSpace shall be responsible for
the work done by its subcontractors, and such work shall be done in compliance with the applicable provisions of this Agreement, including any applicable Work Order, Purchase Order or Exhibit. 

 

	 	(f)	InfoSpace also warrants that the Technology it shall utilize has year 2000 capability. Year 2000 capability means that the Technology utilized by InfoSpace will:

  

	 	(i)	Read, compute, store, process, display and print data involving dates, including single century and multi-century formulas, and will not cause computational, display,
storage or other errors resulting from the liability to accurately or correctly handle dates, including, but not limited to, year 2000 and February 29, 2000; and 

 

	 	(ii)	Include the indication of century in all date-related user interface functionality, data fields, and generated code. 

6.2 Indemnification. 
  

	 	(a)	Cingular will defend, indemnify and hold harmless InfoSpace, and its respective directors, officers, employees and agents, from and against any and all claims, costs,
losses, damages, judgments and expenses (including reasonable attorneys’ fees) arising out of or in connection with any third-party claim alleging (i) any breach of Cingular’s representations or warranties or covenants set forth in
this Agreement or (ii) that any Cingular Materials (excluding the Cingular Customized Work Product) contain any material that is obscene, libelous or defamatory, or violates the rights of any third party, or violates any law or regulation, or
infringes any Intellectual Property Rights of any third party. InfoSpace agrees that Cingular shall have sole and exclusive control over the defense and settlement of any such third party claim. However, Cingular shall not acquiesce to any judgment
or enter into any settlement that adversely affects InfoSpace’s rights or interests without the prior written consent of InfoSpace. InfoSpace shall promptly notify Cingular of any such claim of which it becomes aware and shall: (a) at
Cingular’s expense, provide reasonable cooperation to Cingular in connection with the defense or settlement of any such claim; and (b) at InfoSpace’s expense, be entitled to participate in the defense of any such claim.

  

	 	(b)	 InfoSpace will defend, indemnify and hold harmless Cingular, and its respective directors, officers, employees and agents, from and against any and all
claims, costs, losses, damages, judgments and expenses (including reasonable attorneys’ fees) arising out of or in connection with any third-party claim alleging (i) any breach of InfoSpace’s representations or warranties or covenants
set forth in this Agreement or (ii) that Technology, Cingular Customized Work Product (excluding any materials provided by Cingular to InfoSpace), InfoSpace Sourced Content, InfoSpace Marks, InfoSpace Software, any software licensed by
InfoSpace that is used by InfoSpace to host the Services, or any other materials provided by InfoSpace to Cingular pursuant to this Agreement contain any material that is obscene, libelous or defamatory, or violates the rights of any third party, or
violates any law or regulation, or infringes any Intellectual Property Rights of any third party. Cingular agrees that InfoSpace shall have 

 

 11 

	 	
sole and exclusive control over the defense and settlement of any such third party claim. However, InfoSpace shall not acquiesce to any judgment or enter into any settlement that adversely
affects Cingular’s rights or interests without the prior written consent of Cingular. Cingular shall promptly notify InfoSpace of any such claim of which it becomes aware and shall: (a) at InfoSpace’s expense, provide reasonable
cooperation to InfoSpace in connection with the defense or settlement of any such claim; and (b) at Cingular’s expense, be entitled to participate in the defense of any such claim. Notwithstanding anything herein to the contrary, InfoSpace
shall not have any indemnity obligation or liability to Cingular arising from, or related to, Content accessed by any User through a meta-search Service. 

  

	 	(c)	In the event that either party, after notification of any claim for which such party is responsible, does not assume the defense of such action, such party will
reimburse the other party for all reasonable costs incurred by such other party in the defense of the claim, including, but not limited to, reasonable attorneys’ fees. 

 

	 	(d)	Notwithstanding any other provision hereof, upon notice from Cingular, to the extent that it is within the reasonable control of InfoSpace, InfoSpace shall suspend
access to that portion of the Services, at the time and as identified and as directed by Cingular in such notice, for so long as a claim of obscenity, libel, defamation, or Intellectual Property Right infringement is pending or threatened, until
otherwise directed by Cingular in writing. 

 6.3 Infringement 

 

	 	(a)	Without limiting InfoSpace’s other obligations under Section 6.2, if an injunction or order is obtained against Cingular’s use of any Service (excluding
any Content or Cingular Materials) or if in InfoSpace’s opinion any such Service is or is likely to become the subject of a claim of infringement, InfoSpace will, at its expense: 

 

	 	1)	Procure for Cingular the right to continue using such Service; or 

  

	 	2)	After consultation with Cingular, replace or modify such Service to make it a substantially similar, functionally equivalent, non-infringing Service; or

  

	 	3)	Remove such Service and reduce any recurring fees attributable to such Service. 

 

	 	(b)	In no event will Cingular be liable to InfoSpace for any fees for a Service after the date that InfoSpace no longer provides to Cingular such Service as a result of
actual or claimed infringement. 

  

 12 

 6.4 Insurance 

As of the Effective Date, InfoSpace maintains and will maintain the insurance coverage set forth below: 

 

			
	Commercial General Liability:	  	
		
	Combined Single Limit	  	$1,000,000 per occurrence
		
	General Aggregate	  	$2,000,000 per policy period
		
	Products/Completed Operations Aggregate	  	$2,000,000 per policy period
		
	Internet Professional Liability:	  	
		
	Data Processor’s Errors and Omissions Coverage or similar coverage	  	$1,000,000 per occurrence/aggregate
		
	Information Technology Products Insurance	  	$1,000,000 per occurrence
		
	Personal Injury/Advertising	  	$1,000,000 per occurrence
		
	Umbrella Policy:	  	
		
	$20,000,000 per occurrence	  	
	
	$20,000,000 for products/completed operations aggregate
		
	$20,000,000 general aggregate	  	
		
	Worker’s Compensation:	  	
		
	$1,000,000 bodily injury by accident	  	
		
	$1,000,000 bodily injury by disease	  	

 InfoSpace has provided and shall provide upon request a Certificate of Insurance to Cingular
showing coverage and limits not less than the minimum amounts shown herein. Such insurance coverage shall have an A-VII or better rating, as rated in the A.M. Best Key Ratings Guide for Property and Casualty Insurance Companies. 

All certificates and policies shall include a provision whereby Cingular must be given thirty (30) days advance written notice of the
insurer’s intention not to renew such policy(ies) or to cancel, replace or alter the same by reducing the required coverage. 
  

 13 

 6.5 Limitation of Liability; Disclaimer. 

 

	 	(a)	Liability 

 EXCEPT FOR
(A) CONFIDENTIALITY OBLIGATIONS; OR (B) THE INDEMNITY AND INFRINGEMENT INDEMNITY OBLIGATIONS OF THIS AGREEMENT, NEITHER PARTY WILL BE LIABLE FOR CONSEQUENTIAL, INCIDENTAL, SPECIAL, OR PUNITIVE DAMAGES, OR FOR LOSS OF REVENUE OR PROFIT IN
CONNECTION WITH THE PERFORMANCE OR FAILURE TO PERFORM THIS AGREEMENT, REGARDLESS OF WHETHER SUCH LIABILITY ARISES FROM BREACH OF CONTRACT, TORT, OR ANY OTHER THEORY OF LIABILITY. EXCEPT FOR THE INFRINGEMENT INDEMNITY OBLIGATIONS OF THIS AGREEMENT,
EACH PARTY’S LIABILITY UNDER THIS AGREEMENT WILL NOT EXCEED ***. 
 No Additional Warranties. EXCEPT AS SET FORTH IN THIS
AGREEMENT, NEITHER PARTY MAKES, AND EACH PARTY HEREBY SPECIFICALLY DISCLAIMS, ANY REPRESENTATIONS OR WARRANTIES, EXPRESS OR IMPLIED (INCLUDING ANY IMPLIED WARRANTY OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE AND IMPLIED WARRANTIES ARISING
FROM COURSE OF DEALING OR COURSE OF PERFORMANCE), AND EACH PARTY HEREBY SPECIFICALLY DISCLAIMS ANY CLAIM IN TORT (INCLUDING NEGLIGENCE), IN EACH CASE, REGARDING THEIR WEB SITES, ANY PRODUCTS OR SERVICES DESCRIBED THEREON, OR ANY OTHER ITEMS,
SOFTWARE OR SERVICES PROVIDED UNDER THIS AGREEMENT. EXCEPT AS SET FORTH IN THIS AGREEMENT, CINGULAR ACKNOWLEDGES THAT INFOSPACE MAKES NO WARRANTY THAT THE CONTENT, SERVICES, SOFTWARE OR ANY OTHER MATERIALS ON ITS WEB SITES OR THE SERVERS AND
SOFTWARE THAT MAKES ITS WEB SITES AVAILABLE ARE FREE FROM ERRORS, DEFECTS, DESIGN FLAWS OR OMISSIONS. 
 6.6 Taxes

  

	 	(a)	InfoSpace may invoice Cingular the amount of any federal excise taxes or state or local sales taxes imposed upon the sale of material or provision of services as
separate items, if applicable, listing the taxing jurisdiction imposing the tax. Installation or labor charges must be separately stated. Cingular agrees to pay all applicable taxes to InfoSpace that are stated on and that relate to the materials or
services included on that invoice. InfoSpace agrees to remit taxes to the appropriate taxing authorities. 

  

	 	(b)	InfoSpace agrees to pay, and to hold Cingular harmless from and against, any penalty, interest, additional tax, or other charge that may be levied or assessed as a
result of the delay or failure of InfoSpace, for any reason, to pay any tax or file any return or information required by law, rule or regulation or by this Agreement to be paid or filed by InfoSpace. InfoSpace agrees to pay and to hold Cingular
harmless from and against any penalty or sanction assessed as a result of InfoSpace doing business with any country subject to U.S. trade restrictions. 

  

	 	(c)	Upon Cingular’s request, the parties shall consult with respect to the basis and rates upon which InfoSpace shall pay any taxes for which Cingular is obligated to
reimburse InfoSpace under this Agreement. If Cingular determines that in its opinion any such taxes are not payable or should be 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 14 

	 	(d)	paid on a basis less than the full price or at rates less than the full tax rate, InfoSpace shall make payment in accordance with such determinations and Cingular shall
be responsible for such determinations. If collection is sought by the taxing authority for a greater amount of taxes than that so determined by Cingular, InfoSpace shall promptly notify Cingular. InfoSpace shall cooperate with Cingular in
contesting such determination, but Cingular shall be responsible and shall reimburse InfoSpace for any tax, interest, or penalty in excess of its determination. If Cingular desires to contest such collection, Cingular shall promptly notify
InfoSpace. If Cingular determines that in its opinion it has reimbursed InfoSpace for sales or use taxes in excess of the amount that Cingular is obligated to reimburse InfoSpace, Cingular and InfoSpace shall consult to determine the appropriate
method of recovery of such excess reimbursements. InfoSpace shall credit any excess reimbursements against tax reimbursements or other payments due from Cingular if and to the extent InfoSpace can make corresponding adjustments to its payments to
the relevant tax authority. At Cingular’s request, InfoSpace shall timely file any claims for refund and any other documents required to recover any other excess reimbursements, and shall promptly remit to Cingular all such refunds (and
interest) received. 

  

	 	(e)	If any taxing authority advises InfoSpace that it intends to audit InfoSpace with respect to any taxes for which Cingular is obligated to reimburse InfoSpace under this
Agreement, InfoSpace shall (1) promptly so notify Cingular, (2) afford Cingular an opportunity to participate on an equal basis with InfoSpace in such audit with respect to such taxes and (3) keep Cingular fully informed as to the
progress of such audit. Each party shall bear its own expenses with respect to any such audit, and the responsibility for any additional tax, penalty or interest resulting from such audit shall be determined in accordance with the applicable
provisions of this Section 6.6. InfoSpace’s failure to comply with the notification requirements of this Section 6.6 shall relieve Cingular of its responsibility to reimburse InfoSpace for taxes only if InfoSpace’s failure
materially prejudiced Cingular’s ability to contest imposition or assessment of those taxes. 

  

	 	(f)	Cingular shall be solely responsible for all taxes imposed in connection with the sale of the Services to Users. 

 

	7.	Term and Termination. 

7.1 Term. 
  

	 	(a)	The term of this Agreement shall commence on the Effective Date and, unless earlier terminated pursuant to this Agreement, or except as provided in Section 7.1(b)
or (c), shall end on the second anniversary of the Effective Date (the “Initial Term”). After the Initial Term, this Agreement shall continue until terminated by either party upon six months notice. 

 

	 	(b)	In the event that Cingular elects to host the InfoSpace Software pursuant to Section 4(b), the Term of this Agreement shall end on the “Live Date” as
defined in the License Agreement. 

  

	 	(c)	In the event that Cingular terminates this Agreement pursuant to Section 7.2 and elects to host the InfoSpace Software as described in Section 4(b), the Term
of this Agreement shall end on the “Live Date” as defined in the License Agreement, provided that the Live Date occurs on or before the expiration of the 180 day period following the date of termination. If the Live Date does not occur on
or before the expiration of such 180 day period, this Agreement will terminate on the last day of such 180 day period and thereafter InfoSpace will have no obligation to provide the Services unless the parties agree otherwise in writing.

  

 15 

 7.2 Termination for Breach. Either party may terminate this Agreement upon not less
than thirty (30) days’ prior written notice to the other party of any material breach hereof by such other party, provided that such other party has not cured such material breach within such thirty (30) day period. In the event that
Cingular terminates this Agreement pursuant to this Section 7.2, Cingular may elect, and InfoSpace shall allow Cingular, to host the InfoSpace Software as described in Section 4(b), provided that (i) Cingular provides InfoSpace with
written notice of such election in Cingular’s termination notice; (ii) InfoSpace continues to provide the Services to Cingular under the terms and conditions of this Agreement for a period of time to be agreed by the Parties in writing not
to exceed 180 days during which time the Parties will cooperate to transition the hosting of the InfoSpace Software to Cingular; (iii) Cingular and InfoSpace enter into the License Agreement prior to Cingular hosting the InfoSpace Software; and
(iv) Cingular shall not host the InfoSpace Software at the facilities of a third party without the prior written consent of InfoSpace, which consent shall not be unreasonably withheld or delayed. The term of the License Agreement entered into
pursuant to this Section 7.2 will be for a term of up to six months, as determined by Cingular in its sole discretion, and to be set forth in the License Agreement. 

7.3 Termination for Convenience. After April 22, 2006, either party may terminate this Agreement without cause upon not less
than six months’ prior written notice to the other party. 
 7.4 Effect of Termination. Upon termination of this
Agreement for any reason or expiration of the Term, all rights and obligations of the parties under this Agreement shall be extinguished, except that: (a) all accrued payment obligations hereunder shall survive such termination or expiration;
and (b) the rights and obligations of the parties which by their nature would continue beyond termination or expiration, including Sections 3.11(d), 5, 6.2, 6.3, 6.5, 6.6, 7, 8, and 9.2 through 9.15, shall survive such termination or
expiration. Upon termination or expiration of this Agreement, InfoSpace will promptly return all User Data upon receipt of notification from Cingular. 
  

	8.	Intellectual Property. 

8.1 Cingular. As between the parties and subject to Section 8.2 and Section 3.11(d) and all other relevant provisions of
this Agreement, Cingular retains all right, title and interest in and to the Cingular Materials, along with all Intellectual Property Rights associated therewith and all User Data. As between the parties, Cingular retains all right, title and
interest in the Cingular Sourced Content, any items or Web Site specifications supplied by Cingular, its Affiliates or contractors (including, without limitation, the following: screen colors, fonts and general screen layout specifications of the
“look and feel” supplied by Cingular (excluding the InfoSpace Sourced Content and Technology), and domain names obtained by Cingular). 

8.2 InfoSpace. As between the parties, InfoSpace reserves and retains all right, title and interest, including but not limited to
all Intellectual Property Rights, in and to the Services and the Technology (excluding any Cingular Materials) utilized under or in connection with this Agreement, and no license or title to, nor ownership of, any of the Services or Technology
(excluding any Cingular Materials) is granted or otherwise transferred to Cingular or any other Person except as specifically provided under this Agreement. As between the parties, InfoSpace retains all right, title and interest in and to the
InfoSpace Sourced Content and the InfoSpace Web Sites (including, without limitation, any and all of the content, data, URLs, technology, software, code, user interfaces, “look and feel”, Trademarks associated therewith, but excluding
Cingular Materials) and the InfoSpace Marks, along with all Intellectual Property Rights associated therewith. 
  

 16 

 8.3 Cingular Customized Work Product. InfoSpace shall develop and deliver to Cingular
the Cingular Customized Work Product in accordance with the specifications and schedule set forth on Exhibit L. All right, title and interest, including all Intellectual Property Rights, in and to the Cingular Customized Work Product shall be owned
by Cingular. InfoSpace agrees to assign and, upon its creation, automatically assigns to Cingular the ownership of the Cingular Customized Work Product, including all Intellectual Property Rights associated therewith, without the necessity of any
further consideration. Cingular hereby grants to InfoSpace a personal, non-exclusive, non-transferable, license to use the Customized Work Product to provide the Services in accordance with this Agreement. 

8.4 Copyright Notices. Attribution will take place on the PC Pages and Mobile Pages as specified in Section 3.2. InfoSpace and
Cingular acknowledge that the Co-branded Pages may also contain copyright and patent notices, including those of InfoSpace and its affiliates, Content providers, and of Cingular. If any such notices are required, InfoSpace shall advise Cingular of
the content, screen location, and size of the notice, prior to Cingular’s approval of any Co-branded Pages. 
 8.5 Other
Trademarks. InfoSpace shall not register or attempt to register any of the Cingular Marks or any Trademarks that Cingular reasonably deems to be confusingly similar to any of the Cingular Marks. Cingular shall not register or attempt to register
any of the InfoSpace Marks or any Trademarks that InfoSpace reasonably deems to be confusingly similar to any of the InfoSpace Marks. 

8.6 Further Assurances. Each party shall take, at the other party’s expense, such action (including, without limitation,
execution of affidavits or other documents) as the other party may reasonably request to effect, perfect or confirm such other party’s ownership interests and other rights as set forth above in this Section 8. 

8.7 No Joint Development; Enhancements. The parties contemplate that there will be no joint development of Intellectual Property
under this Agreement. The parties shall not engage in joint development except as they may separately agree, in writing, in advance. Further, in no event shall enhancements, adaptations, improvements, modifications and/or derivative works
(“Enhancements”) created from one party’s pre-existing Intellectual Property be considered to be jointly owned by the parties, regardless of which party creates the Enhancement, it being understood that, subject to any licenses
granted herein, such Enhancements shall be the sole and exclusive property of the owner of the Intellectual Property upon which such Enhancements are based. 

8.8 Restrictions. Neither party shall have any rights to any materials, content or technology provided by the other party
hereunder, except as specifically provided in this Agreement, and neither shall alter, modify, copy, edit, format, translate, create derivative works of or otherwise use any materials, content or technology provided by the other party except as
explicitly provided for herein, or as approved in advance, in writing, by the other party. 
  

	9.	General Provisions. 

9.1 Access 
  

	 	(a)	 When appropriate, InfoSpace shall have reasonable access to Cingular’s premises during normal business hours and at such other times as may be
agreed upon by the parties in order to enable InfoSpace to perform its obligations under this Agreement. InfoSpace shall coordinate such access with Cingular’s designated representative prior to visiting such premises. InfoSpace insures
Cingular that only persons employed by InfoSpace or subcontracted by InfoSpace will be allowed to enter Cingular’s premises. If Cingular requests InfoSpace or its subcontractor to discontinue furnishing any person provided by InfoSpace or its
subcontractor from performing work on Cingular’s premises, InfoSpace shall immediately comply with such request. Such 

 

 17 

	 	
person shall leave Cingular’s premises promptly and InfoSpace shall not furnish such person again to perform work on Cingular’s premises without Cingular’s written consent. The
parties agree that, where required by governmental regulations, it will submit satisfactory clearance from the U.S. Department of Defense and/or other federal, state, or local authorities. 

 

	 	(b)	Cingular may require InfoSpace or its representatives, including employees and subcontractors, to exhibit identification credentials, which Cingular may issue in order
to gain access to Cingular’s premises for the performance of services. If, for any reason, any InfoSpace representative is no longer performing such services, InfoSpace shall promptly inform Cingular. Notification shall be followed by the
prompt delivery to Cingular of the identification credentials, if issued by Cingular, or a written statement of the reasons why said identification credentials cannot be returned. 

 

	 	(c)	InfoSpace shall use commercially reasonable efforts to insure that its representatives, including employees and subcontractors, while on or off Cingular’s
premises, will (i) protect Cingular’s materials, buildings, and structures, (ii) not interfere with Cingular’s business operations, and (iii) perform services with care and due regard for the safety, convenience, and
protection of Cingular, its employees, and property and in full conformance with the policies specified in the Cingular Code of Conduct, which prohibits the possession of a weapon or an implement which can be used as a weapon (a copy of the Cingular
Code of Conduct is available upon request). 

  

	 	(d)	InfoSpace shall be responsible for insuring that all persons furnished by InfoSpace work harmoniously with all others when on Cingular’s premises.

 9.2 Dispute Resolution. 
  

	 	(a)	The parties will attempt in good faith to promptly resolve any controversy or claim arising out of or relating to this Agreement through negotiations between key
representatives of the parties, before resorting to other remedies available to them. 

  

	 	(b)	If a controversy or claim should arise which is not settled as specified in sub Section (a) above, representatives of each party who are authorized to resolve the
controversy or claim will meet at a location designated by Cingular, at least once, and will attempt to, and are empowered to, resolve the matter. Either representative may request this meeting within fourteen (14) days of such request (the
“First Meeting”). 

  

	 	(c)	Unless the parties otherwise agree, if the matter has not been resolved within twenty-one (21) days of the First Meeting, the representatives shall refer the
matter to Senior Executives, who shall have full authority to settle the dispute (herein called the “Senior Executives”). The Senior Executives will make commercially reasonable efforts to meet for negotiations within fourteen
(14) days of the end of the twenty-one (21) day period referred to above, at a site designated by Cingular. Three (3) business days prior to this scheduled meeting, the parties shall exchange memoranda stating the issue(s) in dispute
and their positions, summarizing the negotiations which have taken place, and attaching relevant documents. 

  

	 	(d)	If more than one meeting is held between the Senior Executives, the meeting shall be held in rotation at the offices of InfoSpace and Cingular.

  

	 	(e)	If the matter has not been resolved within thirty (30) days of the First Meeting of the Senior Executives (which period may be extended by mutual agreement), the
parties will attempt in good faith to resolve the controversy or claim via non-binding mediation in accordance with the American Arbitration Association’s rules for Mediation of Business Disputes. 

 

 18 

 9.3 Compliance with Laws 

Both parties shall comply with all applicable federal, state, county, and local rules, including without limitation, all statutes, laws,
ordinances, regulations and codes (“Laws”). Conversely, nothing set forth in this Agreement, including Exhibit E, is intended to contractually obligate either party to comply with any Laws that otherwise are not applicable to it.
The parties’ obligation to comply with all applicable Laws includes the procurement of permits, certificates, approvals, inspections, and licenses, when needed, in the performance of this Agreement. InfoSpace further agrees to comply with the
Executive and Federal regulations, to the extent such regulations are applicable, as set forth in Exhibit E. The parties further agree that each is solely and exclusively responsible for any liability for its own noncompliance with any applicable
Laws and each party shall defend, indemnify, and hold the other party harmless from and against such liability. 
 9.4
Confidentiality. 
 Each party, which receives proprietary and/or confidential information of the other party (the
“Receiving Party”), shall retain in confidence the terms of this Agreement, the Technology, and all other non-public information and know-how of the other party disclosed or acquired by the Receiving Party pursuant to or in
connection with this Agreement which is either designated as proprietary and/or confidential or by the nature of the circumstances surrounding disclosure, ought in good faith to be treated as proprietary and/or confidential (“Confidential
Information”); provided that each party may disclose Confidential Information to its immediate legal and financial consultants and to any Affiliates (and its employees) with a need to know arising as a result of this Agreement, in the
ordinary course of its business. Each party agrees to use commercially reasonable efforts to protect Confidential Information of the other party, and in any event, to take precautions at least as great as those taken to protect its own confidential
information of a similar nature. The foregoing restrictions shall not apply to any information that: (a) was known by the Receiving Party prior to disclosure thereof by the other party; (b) was in or entered the public domain through no
fault of the Receiving Party; (c) is disclosed to the Receiving Party by a third party, until such time as notified by the other party that such third party was not legally entitled to make such disclosure without violation of an obligation of
confidentiality; (d) is required to be disclosed by applicable laws or regulations (but in such event, only to the extent required to be disclosed); or (e) is independently developed by the Receiving Party without reference to any
Confidential Information of the other party. Upon request of the other party, each party shall return to the other all materials, in any medium, which contain, embody, reflect or reference all or any part of any Confidential Information of the other
party. Each party acknowledges that breach of this provision by it would result in irreparable harm to the other party, for which money damages would be an insufficient remedy, and therefore that the other party shall be entitled to seek injunctive
relief to enforce the provisions of this Section 9.4. Without limitation and subject to Section 3.11(d), Confidential Information includes User Data (Section 3.11). 

9.5 Independent Contractors 
  

	 	9.5.1	InfoSpace hereby represents and warrants to Cingular that: 

  

	 	(a)	InfoSpace is engaged in an independent business and will perform all obligations under this Agreement as an independent contractor and not as the agent or employee of
Cingular; 

  

 19 

	 	(b)	InfoSpace’s personnel performing Services shall be considered solely the employees of InfoSpace and not employees or agents of Cingular; 

 

	 	(c)	InfoSpace has and retains the right to exercise full control of and supervision over the performance of the Services and full control over the employment, direction,
assignment, compensation, and discharge of all personnel performing the Services; 

  

	 	(d)	InfoSpace is solely responsible for all matters relating to compensation and benefits of all InfoSpace’s personnel who perform Services. This responsibility
includes, but is not limited to, (1) timely payment of compensation and benefits, including, but not limited to, overtime, medical, dental, and any other benefit, and (2) all matters relating to compliance with all employer obligations to
withhold employee taxes, pay employee and employer taxes, and file payroll tax returns and information returns under local, state, and federal income tax laws, unemployment compensation insurance and state disability insurance tax laws, and social
security and Medicare tax laws, and all other payroll tax laws or similar laws (all collectively hereinafter referred to as “Payroll Tax Obligations”) with respect to all InfoSpace personnel providing services; and

  

	 	(e)	InfoSpace will indemnify, defend, and hold Cingular harmless from all liabilities, costs, expenses, and claims related to InfoSpace ‘s failure to comply with any
of the above provisions. 

  

	 	9.5.2	Cingular and InfoSpace are independent contractors under this Agreement, and nothing herein shall be construed to create a partnership, joint venture, franchise
or agency relationship between Cingular and InfoSpace. Neither party has any authority to enter into agreements of any kind on behalf of the other party and Cingular will not attempt to or create any license, warranty or other obligation, express or
implied, on behalf of InfoSpace or any of its affiliates. 

 9.6 Assignment; Merger. Neither party may
assign this Agreement or any of its rights or delegate any of its duties under this Agreement without the prior written consent of the other party, which consent shall not be unreasonably withheld or delayed. Subject to the foregoing, this
Section 9.6 will be binding upon, enforceable by, and inure to the benefit of the parties and their respective successors and assigns. 

9.7 Choice of Law. This Agreement shall be governed by, and construed in accordance with, the laws of the State of New York,
without reference to its choice of law rules. 
 9.8 Nonwaiver. No waiver of any breach of any provision of this Agreement
shall constitute a waiver of any prior, concurrent or subsequent breach of the same or any other provisions hereof, and no waiver shall be effective unless made in writing and signed by an authorized representative of the waiving party. 

9.9 Force Majeure. Neither party shall be deemed to be in default of or to have breached any provision of this Agreement as a
result of any delay, failure in performance or interruption of service, resulting directly or indirectly from acts of God, acts of civil or military authorities, civil disturbances, epidemics, riots, wars, fires, earthquakes, transportation
contingencies, strikes, or other catastrophes or occurrences, each of which are beyond such party’s reasonable control, provided such default or breach is not directly or indirectly the result, in whole or in part, of its fault or negligence.

  

 20 

 9.10 Notices. Any notice or other communication required or permitted to be given
hereunder shall be given in writing and delivered in person, mailed via confirmed facsimile or e-mail, or delivered by recognized courier service, properly addressed and stamped with the required postage, to the applicable party at its address
specified below and shall be deemed effective upon receipt. Either party may from time to time change the individual to receive notices or its address by giving the other party notice of the change in accordance with this section. 

Addresses for notices: 
  

			
	To Cingular:	  	 To InfoSpace:

		
	 Cingular Wireless LLC
	  	InfoSpace, Inc.
	 5565 Glenridge Connector
	  	 601 108th Ave., NE, Suite 1200

	 Atlanta, GA 30342
	  	 Bellevue, WA 98004

	 Attn: VP SCM
	  	 Attn: EVP, Mobile

		  	 Fax: (425) 201-6110

	 Cc: Chief Counsel SCM
	  	

 However, invoices should be mailed to: 

Cingular Wireless LLC 

5565 Glenridge Connector 

Atlanta, GA 30342 

Attention: Data Products/*** 

In addition, an additional copy of any notice of change of address, or of termination or any alleged breach of this Agreement, shall be
thus sent to the applicable party at the following address: 
  

			
	To Cingular:	  	 To InfoSpace:

		
	Cingular Wireless LLC	  	InfoSpace, Inc.
	5565 Glenridge Connector	  	 601
108th Ave. NE, Suite 1200

	Atlanta, GA 30342	  	 Bellevue, WA 98004

	Attention: Chief Counsel SCM	  	 Attention: General Counsel

		  	 Fax: (425) 201-6110

9.11 Savings. In the event any provision of this Agreement shall for any reason be held to be invalid, illegal or unenforceable in
any respect, the remaining provisions shall remain in full force and effect. 
 9.12 Integration. This Agreement contains
the entire understanding of the parties hereto with respect to the transactions and matters contemplated hereby, supersedes all previous agreements or negotiations between InfoSpace, Inc., InfoSpace and Cingular concerning the subject matter hereof,
including but not limited to (i) Prior Agreement and (ii) the Amended and Restated Letter of Intent, effective as of July 22, 2005, and cannot be amended except in writing signed by InfoSpace and Cingular. In the event of a conflict
or inconsistency between any exhibit made a part of this Agreement and the remainder of this Agreement, such exhibit shall govern. Further, in the event of a conflict or inconsistency between a Work Order and the corresponding Purchase Order, the
Purchase Order will govern. 
 9.13 Counterparts; Electronic Signature. This Agreement may be executed in counterparts,
each of which will be deemed an original, and all of which together constitute one and the same instrument. To expedite the process of entering into this Agreement, the parties acknowledge that Transmitted 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 21 

 Copies of the Agreement will be equivalent to original documents until such time as original
documents are completely executed and delivered. “Transmitted Copies” will mean copies that are reproduced or transmitted via photocopy, facsimile or other process of complete and accurate reproduction and transmission. 

9.14 Conflict of Interest. InfoSpace represents and warrants that no officer, director, employee, or agent of Cingular has been or
will be employed, retained or paid a fee, or otherwise has received or will receive any personal compensation or consideration, by or from InfoSpace or any of InfoSpace’s officers, directors, employees, or agents in connection with the
obtaining, arranging, or negotiation of this Agreement or other documents entered into or executed in connection with this Agreement. 

9.15 Construction and Interpretation 
  

	 	(a)	The language of this Agreement shall in all cases be construed simply, as a whole and in accordance with its fair meaning and not strictly for or against any party. The
parties agree that this Agreement has been prepared jointly and has been the subject of arm’s length and careful negotiation. Each party has been given the opportunity to independently review this Agreement with legal counsel and other
consultants, and each party has the requisite experience and sophistication to understand, interpret, and agree to the particular language of the provisions. Accordingly, in the event of an ambiguity in or dispute regarding the interpretation of
this Agreement, the drafting of the language of this Agreement shall not be attributed to either party. 

  

	 	(b)	Article, section, or paragraph headings contained in this Agreement are for reference purposes only and shall not affect the meaning or interpretation of this
Agreement. The use of the word “include” shall mean “includes, but is not limited to.” The singular use of words shall include the plural use and vice versa. 

 

	 	(c)	Cumulative Remedies: Except as specifically identified as a party’s sole remedy, any rights of cancellation, termination, liquidated damages, or other remedies
prescribed in this Agreement are cumulative and are not exclusive of any other remedies to which the injured party may be entitled. Neither party shall retain the benefit of inconsistent remedies. 

IN WITNESS WHEREOF, the parties have duly executed this Agreement as of the Effective Date. 

 

									
	 Cingular Wireless LLC

on behalf of itself and its Affiliates
	 		 	InfoSpace Mobile, Inc.
					
	By:	 	***	 		 	By:	 	***
	Name:	 	***	 		 	Name:	 	***
	Title:	 	VP - Network Supply Chain	 		 	Title:	 	President

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 22 

			
	 InfoSpace, Inc.

solely with respect to Section 9.12

		
	By:	 	***
	Name:	 	***
	Title:	 	CAO

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 23 

 EXHIBIT A - SERVICES 

 

 A. Services. Subject to the terms and conditions of this Agreement, InfoSpace will, in
cooperation with Cingular, design, develop, implement, host and maintain the services described in Section B below (collectively, the “Services”) on a mutually agreed schedule. Cingular will design and supply the graphical content to be
used in connection with the Services, and InfoSpace will be responsible for implementing the graphical user interface and related design elements for the Services. 

B. Description of Services. 
  

	 	1.	Platform and Services; Legacy Services. 

  

	 	a.	Platform and Services. InfoSpace will use the InfoSpace platform components set forth in the table below to make the corresponding Services available to Cingular
on a mutually agreed schedule. 

  

			
	 Platform Component
	  	 Service Description

	 Content Management
	  	
		
	Content Management System (CMS)	  	Aggregates, formats, and distributes content (feeds, images, etc.) to downstream application servers.
		
	Content Publishing System (CPS)	  	 Configures, publishes and restores WAP deck structure. CPS is comprised of the following:

 
 •   Deck Authoring Tool
(DAT): allows an Administrator to create a deck structure. This includes the ability to assign links, device-specific decks, service specific decks, folders and sub-folders; assign meta-data to deck objects; assign interstitials to a deck and/or
folder; set permissions for Users to create customized decks; and assign parental control settings for deck objects.
  

•   Publication Authoring Tool (PAT): allows an Administrator to aggregate Web page assets
(templates, order, style, page level parental control settings) for publishing to the Publication Runtime System (PRS) and to create WAP Pages for use as either WAP Push Landing Pages, Promotions, Help, Terms and Conditions, Category Pages, or WAP
Page Interstitials.
  

•   Content Asset Tool (CAT): allows an Administrator to manage content assets (image, links,
text, content-level parental control settings, etc.) that are uploaded into the system.
  

•   Content Provider Management Tool (CPMT): enables the on-boarding / creation of links from
third party content provider and associated parameters (including link-level parental control settings) for that provider.

  

 24 

 EXHIBIT A - SERVICES 

 

			
	 Platform Component
	  	 Service Description

		  	 •   Feed Management Tool (FMT): Enables the on-boarding of standard RSS
feeds into the CPS environment
  

•   Distribution Service Manager (DSM): Enables the releasing and rollback of labeled content
to the runtime environment.
  

•   Workflow Version Management System (WVMS): exposes a workflow and versioning interface to
Infospace applications
  
 CPS all supports the following
functionality:
  

•   Preview prior to publishing

 
 •   Search of CPS
entries
  

•   Audit Reporting

		
	Runtime Systems	  	 Facilitates the construction and deployment of the User Interface on the Mobile Pages and PC Pages, and includes the
following:
  

•   Deck Runtime Service (DRS): runtime database providing the reference deck for baseline
user experience and supporting User customizations.
  

•   Publication Runtime Service (PRS): serves templates and asset references for construction
of Web Pages.
  

•   Application Runtime Service (ARS): suite of web services that are backed by feeds from
the CMS system.
  

•   Mobile Portal Framework: connects the Runtime Systems to the Rendering
Engine.

		
	Rendering Engine	  	Presents the User Interface for both the Mobile Pages and PC Pages by leveraging various Runtime Services for page construction. The Rendering Engine supports
“single-authoring” and optimizes the User Interface rendered based upon Wireless Device capabilities.
		
	Device Management	  	 Analyzes Wireless Device parameters; allows for the customization of Wireless Device parameters; and makes available Wireless Device
parameters by publishing to target Runtime Systems. Device Management is comprised of the following:
  

•   Device Manager: tool that allows for the addition, deletion, copying, updating, and
publishing of mobile device information.
  

•   Device Monitoring Service: service that resides on a Runtime System waiting for update
notifications in order to process updates from Device Manager.

  

 25 

 EXHIBIT A - SERVICES 

 

			
	 Platform Component
	  	 Service Description

	 Personalization
	  	
		
	Alert Engine	  	Stores User-initiated alert configurations (SMS, MMS, and WAP Push) that trigger information to be delivered to the User’s Wireless Device.
		
	Context Engine	  	Tracks and collates disparate information about Users to help categorize/segment Users for real-time recommendation behavior (e.g. categorization of browse
transactions).
		
	Infospace Message Gateway	  	Connects to Cingular messaging components (SMSC, MMSC, and PPG) to support delivery and receipt of transactions that result in the final delivery of a SMS, MMS or WAP Push message
delivered to a User’s mobile device.
		
	Parental Control	  	 Allows Cingular to identify “Cingular-safe” versus “Cingular-unsafe” content. Cingular determines what is considered
“Cingular-safe” versus “Cingular-unsafe” in its sole discretion.
  

The Parental Control component is comprised of:
  

•   User-Facing: allows post-paid Users to enable Parental Control and to establish a
Parental Control Pass Code (4-digit). Default setting for all Users will be “Cingular-Unsafe”
  

•   Administrator-Facing:

 
 •   Allows designated
Customer Service representatives to configure Parental Control settings on behalf of a pre-paid or post-paid User.
  

•   Allows designated Marketing / Product Realization personnel to assign a Parental Control
setting to deck objects.
  

•   Allows designated Marketing / Product Realization personnel to leverage CPS Search and
Reporting functionality to extract a “Whitelist” for “Cingular-Safe” content that will be used by Cingular’s WAP Gateways.
  

Parental Control settings restrict access to Content on Wireless Devices in the following areas:

 
 •   Navigational Content

  

 26 

 EXHIBIT A - SERVICES 

 

			
	 Platform Component
	  	 Service Description

		  	 •   Search Results

 
 •   Push Parental
Control parameters to other 3rd Party Content Partners

		
	PIM / Email	  	Allows Users to store and manage personal information such as calendar / to-do entries, address book entries and email (Cingular owned email domain). The platform provides service
level spam filtering, email quotas, email filtering and alerting and calendar / to-do alerts.
		
	Recommendation Engine	  	Leverages a User’s context (profile, segmentation, etc.), to provide real-time recommendations in terms of Search Results, recommended changes to the Home Deck, and potentially
Content for purchase.
		
	User Manager	  	Intelligent repository for all User, Administrator and application (Infospace and third party) credentials and profile information. Securely manages authentication, authorization,
session, and information management.
		
	Search	  	
		
	MetaSearch Engine	  	 Aggregates search entities and can return a “unified” result set which is an amalgamation and weighting of the disparate
results returned from several search engine providers.
  
 Cingular intends
to aggregate:
  

•   Google Image Search

 
 •   CellMania

 
 •   Motricity

 
 •   Portal
Crawler

		
	Intellifind Engine	  	Powers Cingular’s “Direct Answer” functionality.
		
	Portal Crawler Engine	  	Indexes Content, including Content hosted by third party content providers such as CNN, ESPN, etc. As links to third party content are added to the deck structure on the Mobile
Pages, the Portal Crawler Engine can be configured to crawl that new site.

  

 27 

 EXHIBIT A - SERVICES 

 

			
	 Platform Component
	  	 Service Description

	 Back Office Tools
	  	
		
	Management Console	  	 Unified administrative console framework that hosts the back office tools associated with the Infospace platform. It is hosted in a
secure environment, requires Administrator credentials (username / password) for access, and only allows access to those Tools for which the Administrator has been granted access.

 
 Back Office Tools include:

 
 •   Administrator
Management
  

•   Care Tool
  

•   User Management

 
 •   CPS

 
 •   Top Search Results
Tool
  

•   Device Manager

 
 •   Campaign Management

		
	Utilities	  	
		
	Batch Dispatcher	  	Receives secure notification of changes to User credential and/or profile data from Cingular and processes those changes throughout the Infospace platform.
		
	Data Developer Program (DDP) Support	  	 Two systems for participating Cingular DDP content providers to interact with the Infospace platform:

 

1.      Content Provider Push Parameters Service (CPPPS) – User data
push
  
 This service will securely push User property
values to content providers as configured by an Administrator using the Content Provider Management Provisioning Tool (CPMPT).
  

2.      Get Subscriber Data Content Provider Pull Service (GSDCPPS) – User
data pull
  
 Content providers that are registered in
the Infospace User Manager will be able to request User-specific profile data.
  

3.      Bookmark API

 
 Utility which allows Users to add third party active links from
Content Provider sites.

  

 28 

 EXHIBIT A - SERVICES 

 

			
	 Platform Component
	  	 Service Description

	 Business Intelligence / Marketing Tools

		
	Campaign Manager (neé Scenario Manager)	  	 Enables Cingular to segment User population based on a variety of parameters to target a specific User segment for various promotions,
including, but not limited to, WAP Push promotions, and is comprised of the following:
  

•   Scenario Creation Tool

 
 •   Segmentation
Identification Tool
  

•   Promotion Association Tool

		
	Business Intelligence Event Management System	  	Normalizes business events for ingestion by the Mobile Data Mart.
		
	Mobile Data Mart	  	Supports Business Intelligence and Campaign Management segmentation needs. The Mobile Data Mart will initially be hosted in an environment that is not dedicated to Cingular, but
securely partitions Cingular data. It provides access to standard usage reports containing agreed upon parameters which can be dimensioned by a Cingular Administrator for detailed analysis.
		
	Reporting Metadata Management Tool	  	 Allows Administrator to categorize URLs, and includes the following functionality:

 
 •   Administrator
interface to view domain, sub-domain and full URL and associated category
  

•   Administrator can manually categorize a URL

 
 •   Administrator can
define metadata and categorization rules for URLs
  

•   Administrator can apply rules to set of URLs for automatic
classification

		
	Delivery Technology	  	
		
	MO SMS	  	User-initiated content-pull service using short text codes. This can be accomplished by providing pre-determined codes or “Default” codes or by allowing Users to establish
their own custom codes. The interface for this experience is provided via the PC Pages.
		
	(Mobile Originated SMS)	  	When the User originates an SMS message by sending a short text code. InfoSpace delivers Content to Cingular’s SMSC using mobile-terminated short-message
delivery.
		
	 MT SMS
  

(Mobile Terminated SMS and InfoAlerts)
	  	 Time and event-triggered content push service.
  

Users set up a personal profile using the PC Pages and select Content to be sent to their Wireless Devices at specified times or upon the occurrence of
certain events. InfoSpace delivers Content to Cingular’s SMSC using mobile-terminated short-message delivery.

  

 29 

 EXHIBIT A - SERVICES 

 

			
	 Platform Component
	  	 Service Description

	WAP Push	  	 User initiated time triggered WAP Push service
  

Users set up a personal profile using the Mobile Pages and select Content to be sent to their Wireless Devices at specified times. InfoSpace delivers
Content to Cingular’s Push Proxy Gateway (PPG) and Cingular delivers the Content from the PPG to Users.

		
	WML / XHTML	  	User-initiated WAP sessions from Wireless Devices.
		
	HTML PC	  	User-initiated browsing sessions from PC or HTML-browser equipped devices supporting IE 4.0 and above and Netscape 4.7 and above.

The table set forth above may be updated from time to time during the Term upon mutual agreement of the parties pursuant to the process
set forth in Exhibit D. 
  

	 	b.	Legacy Services. For a period to be mutually agreed by the parties, InfoSpace will continue to make the following services available: 

 

			
	 Component
	  	 Description

	HTML PC / PC Pages	  	 Provides Users the ability to configure MO-SMS, MT-SMS and MT-MMS Alerts; and access their Cingular Personal Information Manager and
Email (PIM / Email).
  
 As of the Effective Date, PC Pages are hosted within
the Bellevue Data Environment, which is not dedicated to Cingular. In this current configuration, this component is not available for hosting outside of Infospace data facilities.

 
 User data location:

 
 •   Alerts: provisioned
MO-SMS, MT-SMS and MO-MMS alerts are hosted within the Bellevue data environment.
  

•   User Management: identity, credentialing, and profile data is hosted in the Cingular
dedicated data environment located in Infospace’s Boston data center.

  

 30 

 EXHIBIT A - SERVICES 

 

			
	 Component
	  	 Description

		  	 •   Infospace hosted PIM / Email Data: all PIM / Email User data is hosted
in the Cingular dedicated data environment located in Infospace’s Boston data center.
  

Within a mutually agreed to schedule, PC Pages shall be migrated to the Cingular dedicated data environment located at Infospace’s Boston data
center.

		
	WML 1.1 Mobile Pages	  	 The User experience for devices only compatible with the WML 1.1 browser standard will be served by the existing WAP Platform located at
Infospace’s Bellevue data center.
  
 These Mobile Pages are hosted
within the Bellevue data environment, which is not dedicated to Cingular. In this current configuration, this component is not available for hosting outside of Infospace data facilities.

 
 User data location:

 
 •   User Management:
identity, credentialing, and profile data is hosted in the Cingular dedicated data environment located in Infospace’s Boston data center.
  

•   Infospace hosted PIM / Email Data: all PIM / Email User data is hosted in the Cingular
dedicated data environment located in Infospace’s Boston data center.
  

Within a mutually agreed to schedule, the WML 1.1 Mobile Pages shall be integrated with the Services provided via WML / XHTML.

		
	HTML PDA / Treo Site	  	 The HTML PDA or “Treo Site” provides PDA users with a site that allows for SMS Alert configuration and browsing of content.
Infospace hosted PIM / Email is not available to PDA Users.
  
 The HTML PDA
site is hosted within the Bellevue data environment, which is not dedicated to Cingular. In this current configuration, this component is not available for hosting outside of Infospace data facilities.

 
 User data location:

 
 •   Alerts: provisioned
MO-SMS, MT-SMS and MO-MMS alerts are hosted within the ASP Data Environment located in Infospace’s Bellevue data center.

  

 31 

 EXHIBIT A - SERVICES 

 

			
	 Component
	  	 Description

		  	 •   User Management: identity, credentialing, and profile data is hosted in
the Cingular dedicated data environment located in Infospace’s Boston data center.
  

Within a mutually agreed to schedule, the HTML PDA Pages shall be integrated with the Services provided via WML / XHTML.

		
	Alerts	  	Infospace Alert Applications for MT-SMS, MO-SMS, and Alerts use Infospace Sourced Content.
		
	Deck Manager	  	Deck Manager is the component that facilitates the creation of WAP Decks for the WML 1.1 User Experience.

The table set forth above may be updated form time to time during the Term upon mutual agreement of the parties pursuant to the process
set forth in Exhibit D. 
 Content 

Cingular Sourced Content. Cingular will obtain all necessary rights for InfoSpace to distribute the third party
content set forth in Tables (1) and (2) below (collectively, the “Cingular Sourced Content”) in the specified formats, as contemplated by and pursuant to the terms and conditions of this Agreement. InfoSpace will
distribute the Cingular Sourced Content as specified in the table below.  
 Table 1: Cingular Sourced Content 

 

																			
	***	  		  		  		  		  		  		  		  		  	

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 32 

 EXHIBIT A - SERVICES 

 

 Table 2: Cingular Sourced Content - Search 

*** 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission

  

 33 

 EXHIBIT A - SERVICES 

 

 The tables set forth above may be updated from time to time during the Term upon mutual agreement of the
parties pursuant to the process set forth in Exhibit D 
 Integration with Cingular Content and Services: InfoSpace will integrate links
on the Services to designated locations on Web Sites hosted by Cingular for the purpose of providing User administrative services (e.g. customer care, billing, etc.) in a manner and on a schedule to be mutually agreed upon by the parties at no
additional cost to Cingular. 
 b. Infospace Sourced Content. InfoSpace will (i) obtain all necessary rights for
InfoSpace to distribute the third party content set forth in Tables (1), (2), (3) and (4) below (collectively, the “InfoSpace Sourced Content”); and (ii) make the content set forth in Tables (1), (2) and
(4) available to Cingular and the Users via the delivery technologies specified therein in accordance with this Agreement. In addition, InfoSpace will make the content set forth in Table (3) available to Cingular and the Users via the
delivery technologies specified therein for a period to be mutually agreed in writing by the parties. 
 Table 1: Infospace Sourced
Content (New) 
 *** 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 34 

 EXHIBIT A - SERVICES 

 

 Table 2: Infospace Sourced Content – Destination Applications (New) 

*** 
 Table 3: Infospace Sourced Content
(Legacy) 
 *** 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission

  

 35 

 EXHIBIT A - SERVICES 

 

 Table 4: InfoSpace Sourced Content - Search 

*** 
 The tables set forth
above may be updated from time to time during the Term upon mutual agreement of the parties pursuant to the process set forth in Exhibit D 

Modification of Infospace Sourced Content. Notwithstanding Section 2.3(i) of this Agreement, InfoSpace may modify InfoSpace
Sourced Content that is sourced from third parties (a “Content Modification”). Prior to any Content Modification, InfoSpace will provide Cingular with as much advance notice as reasonably possible. In the event that Cingular
reasonably determines that a Content Modification will materially adversely affect the Services, both parties agree to promptly discuss Cingular’s concern and to use good faith efforts to agree to a mutually agreeable solution. In the
event that a proposed Content Modification is due to an increase in cost for existing InfoSpace Sourced Content, Cingular may require InfoSpace to continue to provide such existing InfoSpace Sourced Content to Cingular, provided that Cingular pays
to InfoSpace an additional fee equal to such increase in cost. 
  

	 	3.	PIM / Email Service 

InfoSpace will provide Cingular the following PIM services, on the PC Pages and the Mobile Pages: 

 

	 	•	 	 Web-based email: InfoSpace will provide up to 10MB of disk storage for folders and email archives per mailbox; additional storage is subject to
mutually agreeable terms and conditions, including additional fees. 

  

	 	•	 	 Web-based aggregation of POP3 or IMAP email from up to three other email accounts 

 

	 	•	 	 Calendar 

  

	 	•	 	 Address Book 

  

	 	•	 	 To Do List 

  

	 	•	 	 SMS alerts on Calendar events, To Do items, and Email 

 

	 	•	 	 Enhanced alerting and filtering Module 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 36 

 EXHIBIT A - SERVICES 

 

	 	4.	Personalized / Customized Content. InfoSpace will make the following personalization / customization features available to Users. The table set forth below may
be updated from time to time during the Term upon mutual agreement of the parties pursuant to the process set forth in Exhibit D. 

  

						
	 Personalized / Customization Feature
	  	For
HTML
PC
Access	  	For
WML
/
XHTML
Access
			
	 Active Links / Bookmarks:

User specifies category and gets “active content” and links presented on the home deck
	  		  	Ö	 
			
	 Personalize information when possible, specifically:

 
 •   provide
locally-relevant information based up User’s zip code
  

•   provide personally-relevant information based upon User’s birth date
	  		  	Ö	 
			
	 User customization of the various portal application, such as:

 
 •   Favorite
Sports
  

•   Favorite Theatres
	  		  	Ö	 
			
	 User customization of category pages, specifically “Top Sites”
	  		  	Ö	 
			
	 User customization of the home page
	  		  	Ö	 
			
	 User initiated Alert configuration, including alert preferences, such as:

 
 •   Time of
day
  
 •   Event
based
	  		  	Ö	 

C. InfoSpace Supported Handsets. 

1. Current Devices. InfoSpace will make the Services available in WML and XHTML format, as appropriate, that conforms to standards
for devices and browsers that (i) are commercially available to Cingular customers (ii) have been certified by InfoSpace for the Services, and (iii) that Cingular provides a minimum of four (4) of each such device to InfoSpace
for testing purposes at no charge to InfoSpace. In order to support Infospace maintaining a suitable testing environment for such devices, Cingular will allow InfoSpace reasonable access to Cingular’s wireless network for such testing. As of
the Effective Date, InfoSpace will make the Services available on the following Wireless Devices via the specified browsers (the “InfoSpace Supported Handsets”): 

*** 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 37 

 EXHIBIT A - SERVICES 

 

	2.	New Devices. 

 Cingular
may request that the display of the Services made available in WML and XHTML format conform to standards for devices and/or browsers in addition to those set forth above. When this occurs, Cingular shall deliver to InfoSpace a prototype device that
is functional in all material respects, at no charge to InfoSpace. Upon receipt of a prototype device that is functional in all material respects, and a Change Request from Cingular (as described in Exhibit D), InfoSpace will use commercially
reasonable efforts to provide a written response to Cingular outlining expected turn around time for device profiling and readiness for production support within ten (10) business days of such request. Cingular will provide to InfoSpace a
minimum of four prototype devices that are functional in all material respects for use by InfoSpace in connection with performing such services. Infospace will then profile the devices in a manner and on a schedule to be mutually agreed upon by the
parties at no additional cost to Cingular. 
 Such devices shall have WAP browsers that adhere to industry specifications for
either WML or XHTML (aka WAP 2.0). In the event that a device does not have a browser that conforms to industry specifications, Infospace and Cingular will work together to determine how best to support the device within thirty (30) business
days of Infospace learning that the device does not conform to specifications. In some instances, Infospace will require Cingular to pay for additional work required to support the device service to Cingular’s satisfaction. In such event,
Infospace will provide a written quote to Cingular in response to such request within five (5) business days of coming to agreement on Infospace’s course of action to support the device. Upon Cingular’s acceptance of such quote, the
parties may enter into a mutually 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 38 

 EXHIBIT A - SERVICES 

 

 agreeable Work Order for such services (as set forth in Exhibit D). In order to support
Infospace maintaining a suitable testing environment for such devices, Cingular will allow InfoSpace reasonable access to Cingular’s wireless network for such testing. The parties acknowledge that there are a number of devices not currently
supported by InfoSpace, including but not limited to those set forth in the table below. 
  

	3.	Cingular Network; Gateways. 

Cingular shall be solely responsible for the performance of the Cingular Network and any gateways used in connection with the Services.
Upon request by Cingular, InfoSpace shall use commercially reasonable efforts to assist Cingular to resolve performance problems with gateways related to the Services. Cingular agrees to use commercially reasonable efforts to require gateway
vendors’ employees and experts with respect to such gateways to be available to InfoSpace for consultation on an as needed basis at no charge to InfoSpace. 
  

	4.	Additional Support. 

Integration between handheld devices, the Cingular Network/ gateways, PCs and content providers shall be supported with reasonable
commercial efforts by both InfoSpace and Cingular, except in cases where the integration effort does not require InfoSpace involvement. Costs for this additional effort will be quoted to Cingular and agreed upon in writing prior to InfoSpace’s
commencement of work, as set forth in Exhibit D. 
 D. Reporting. InfoSpace will provide to Cingular the reports described below.
Infospace will store data for such reports for a period of 36 months from the time each report is made available to Cingular. The Mobile Data Mart interface and output may be updated in accordance with the processes outlined in Exhibit D.

 

	 	a.	Usage Reports 

*** 

 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 39 

 EXHIBIT A - SERVICES 

 

	 	b.	Legacy Usage Reports 

  

	 	•	 	 Service Usage Report 

This report will show usage by Category, SubCategory, Language, ServiceLevel, DeviceType, Day, Month. The report will contain data for the
past 12 months. 
 Delivery Mechanism: *** 

DeviceType: Web, Phone/Pager, SMS Messages 
  

	 	•	 	 Carrier Summary Report 

This report will show user statistics including active users and growth. 

Delivery Mechanism: *** 
  

	 	•	 	 Registrations 

This report will show user activity including adds and deletes. 

Delivery Mechanism: *** 
  

	3.	Legacy Alerts Reports 

  

	 	•	 	 This report will contain User alert information from the alerts database 

 

	 	•	 	 Format: tab-delimited text fields. 

  

	4.	General Services Reports 

 InfoSpace will
make available the following reports on the current Cingular extranet reporting site. Infospace will continue to look for ways to improve and enhance these reports but will not make changes without Cingular’s consent. Cingular, at any
time, may request that InfoSpace make changes to these reports on a mutually agreed time frame. The clickaway reporting (click tracking of off-deck sites) will end upon launch of the Services. 

 

	 	•	 	 Clicks 

  

	 	•	 	 Daily Clicks and Page Views 

  

	 	•	 	 Monthly Unique Users 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 40 

 EXHIBIT B - TRADEMARKS 

 

	(i)	InfoSpace Marks: 

 Those trademarks of
InfoSpace set forth at http://www.infospaceinc.com/about/legal_trademarks.php, which may be modified and updated by InfoSpace from time to time. 
  

	(ii)	Cingular Marks  

  

							
	 Registered Trademarks
	  	 Pending Trademark
Applications

	CINGULAR	  	AIRLOADER	  	ALL OVER	  	AWE
				
	CINGULAR HOME	  	ARRIVE SAFELY and Design	  	ALLOVER	  	AWS
				
	CINGULAR NATION	  	CAMPUS ADVANTAGE	  	ALLOVER NETWORK	  	EMINUTES
				
	CINGULAR PROMISE	  	COMAGINE	  	ANSWER TONES	  	FREE-2-BE REWARDED
				
	CINGULAR REGION	  	CUSTOMERS FIRST	  	CINGULAR FITS YOU BEST	  	GREENLIGHT
				
	CINGULAR ROLLOVER	  	FLASHPOINT	  	CINGULAR SMARTCHIP	  	INFOMODE
				
	CINGULAR WIRELESS	  	FREE2GO WIRELESS	  	CINGULAR SOUNDS	  	IT CHANGES EVERYTHING
				
	EXPRESSORIES	  	GO PHONE	  	CINGULAR TAKE CHARGE	  	LINK+SYNC
				
	EXPRESSWEAR	  	GOPORT	  	MARCANDO EL ESTADAR	  	MDRIVE
				
	FAST FORWARD	  	HOW MANY BARS DO YOU HAVE?	  	MORE BARS IN MORE PLACES	  	MGEN
				
	KEEP IN CONTACT	  	HOW WILL YOU USE IT?	  	PEEK AND PAY	  	MINUTES WITHOUT LIMITS
				
	KIC	  	IMAGINE	  	QUICKREACH	  	MYFIVE
				
	MI VENTANA MOVIL	  	LOCAL WITHOUT LIMITS	  	RAISE THE BAR	  	MZONE
				
	MINUTESHARE	  	MESSAGEFLASH	  	RAISING THE BAR	  	ON THE WIRELESS SERVICE AMERICA TRUSTS

  

 41 

 EXHIBIT B - TRADEMARKS 

 

							
	MOBILE2HOME	  	MLIFE	  	SIGNAL BARS Design	  	PRESSTALK
				
	MY WIRELESS WINDOW	  	MMODE	  	TRENDFORCE	  	ROAD TRIP MINUTES
				
	ROLLOVER	  	SURF LOUNGE	  	TRUE SOUND	  	SURE RATE
				
	ROLLOVER MINUTES	  	TXT-411	  	TRUEST SOUND	  	TALKMODE
				
	VOICE CONNECT	  	VOICETOUCH	  	ALL OVER	  	THE WIRELESS CARRIER AMERICA TRUSTS
				
	WHAT DO YOU HAVE TO SAY?	  	WIN ADVANTAGE	  		  	UNETE MAS
				
	WIRELESS BUILT AROUND YOU	  	WORLDCONNECT	  		  	WIRELESS DIGITS
				
	X-MAN Design (Jack Logo)	  		  		  	WIRELESS INFORMATION NETWORK
				
		  		  		  	WORKWARE
				
		  		  		  	YOUR MOBILE LIFE MADE BETTER
				
		  		  		  	 YOUR WORLD.
 CLOSE AT HAND.

  

 42 

 EXHIBIT C – COMMERCIAL TERMS 

 

	A.	Portal User Fee; SMS Fee; Active User Fee. 

Following each calendar month of the Term, InfoSpace will provide Cingular with a written report based on InfoSpace data indicating the number of Portal
Users, SMS Messages and Active Users for such month. Based on such report, InfoSpace will invoice Cingular for an amount equal to the sum of the Portal User Fee, the SMS Fee and the Active User Fee for such month. 

Subject to Section 5.2 of the Agreement, Cingular will pay InfoSpace the invoiced amount within forty-five (45) days of the date of invoice.

  

	1)	Portal User Fee 

 Cingular will pay
Infospace a fee based on the total number of Portal Users for each calendar month of the Term. Infospace will calculate the Portal User Fee as follows: 

*** 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 43 

 EXHIBIT C – COMMERCIAL TERMS 

 

 2) SMS Fee 

Cingular will pay Infospace a fee based on the total number of SMS Messages for each calendar month of the Term. Infospace will calculate the SMS Fee as
follows: 
 *** 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 44 

 EXHIBIT C – COMMERCIAL TERMS 

 

 3) Active User Fee 

Cingular will pay Infospace a fee based on the total number of Active Users for each calendar month of the Term. Infospace will calculate the Active User
Fee as follows: 
 The greater of *** (the “Monthly Minimum”) or the aggregate value of the following calculations: 

*** 
 In the event that the Active User Fee
exceeds *** for three consecutive months of the Term, InfoSpace will waive the Monthly Minimum for the subsequent months of the Term; provided that, in the event the Active User Fee is less than *** for three consecutive months of the Term, the
Monthly Minimum will be reinstated. Notwithstanding the foregoing, the Monthly Minimum will apply to any month of the Term during which Cingular redirects more than *** to another Web Site as described in Section 2.7 of this Agreement.

 B. Fees for Legacy Services. At the end of each calendar month during the first six months of the Term, Cingular shall pay to
InfoSpace a fee *** (the “Legacy Services Fee”). InfoSpace will invoice Cingular for the Legacy Services Fee following each applicable month of the Term and, subject to Section 5.2 of the Agreement, Cingular will pay InfoSpace
the invoiced amount within forty-five (45) days of the date of invoice. In the event that Cingular wishes InfoSpace to provide Legacy Services to Cingular after the first six months of the Term, the parties will renegotiate the Legacy Services
Fee in good faith to cover the extended period for which InfoSpace will provide Legacy Services. 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 45 

 EXHIBIT D – CHANGE REQUEST AND ACCEPTANCE TEST PROCESS 

 

 A. Major Development Process: The following describes the process to be used by
the parties for major enhancements to the Services and/or the introduction of new functionality to the Services. 
  

	 	1.	Cingular submits a business requirements document, in the form attached as Exhibit H (“BRD”). 

 

	 	2.	InfoSpace reviews the BRD and returns a high-level time/cost estimate within a mutually agreed timeframe. 

 

	 	3.	Upon approval of the high level estimate, InfoSpace creates a Work Order, in the form attached as Exhibit J (“Work Order”) along with a Statement of Work that
further defines the deliverable. 

  

	 	4.	Upon approval of the Work Order, Cingular provides Infospace with a Cingular Purchase Order in the form attached as Exhibit J (“Purchase Order”)

  

	 	5.	Cingular and InfoSpace jointly review and refine the requirements. This review is to clarify any ambiguity in the original document and expose the need for any
additional information prior to the creation of the detailed specifications. 

  

	 	6.	InfoSpace creates detailed use cases and functional specifications (and returns another estimate if necessary) within mutually agreed timeframe. Use cases and
functional specifications should clearly map back to the business requirements using the requirements in the original BRD provided by Cingular. 

  

	 	7.	Cingular and InfoSpace jointly review and refine use cases and functional specifications (including test cases and test plans). 

 

	 	8.	If necessary, InfoSpace revises Work Order, and Cingular signs Work Order giving final approval for development based on the revised specifications.

  

	 	9.	InfoSpace countersigns Work Order and development begins. 

  

	 	10.	InfoSpace and Cingular jointly conduct weekly project meetings to provide project status updates and address any outstanding issues/concerns. 

 

 46 

 EXHIBIT D – CHANGE REQUEST AND ACCEPTANCE TEST PROCESS 

 

 B. Change Request Process: The following describes the process to be used by the
parties for minor modifications to the Services. 
  

	 	1.	Cingular submits change request, in the form attached as Exhibit I (“Change Request”). 

 

	 	2.	InfoSpace reviews Change Request and returns a high level time/cost estimate and Work Order within mutually agreed timeframe. 

 

	 	3.	Cingular and InfoSpace jointly review the requirements. 

  

	 	4.	InfoSpace creates detailed use cases and functional specifications (and returns another estimate if necessary) within mutually agreed timeframe.*

  

	 	5.	Cingular and InfoSpace jointly review and refine use cases and functional specifications (including test cases and test plans).* 

 

	 	6.	If necessary, InfoSpace revises Work Order, and Cingular signs Work Order giving final approval for development based on the final specifications.*

  

	 	7.	Upon approval of the Work Order, Cingular provides Infospace with a Cingular Purchase Order in the form attached as Exhibit J (“Purchase Order”)

  

	 	8.	InfoSpace countersigns Work Order and development begins. 

  

	 	9.	Changes are placed in demo for Cingular’s testing/review. 

  

	 	10.	Changes are pushed to production, only upon written approval from Cingular. 

 

	*	These steps may not be required for all change requests (for example: minor copy changes or replacing ads of the same size). 

 

 47 

 EXHIBIT D – CHANGE REQUEST AND ACCEPTANCE TEST PROCESS 

 

 C. Acceptance Test Process 

Unless otherwise agreed by the Parties, this Exhibit D describes the process used to test and accept features for inclusion on the
Services (the “Acceptance Test Process”). The parties will cooperate in good faith to develop and implement communication mechanisms such that Cingular provides feedback to InfoSpace in a timely and efficient manner in order to
facilitate Infospace’s ability to address such feedback. Cingular shall have the right to review and test any Deliverable to determine whether it conforms to specifications or acceptance criteria in the applicable Work Order or SOW (if any) or
as otherwise agreed upon in writing by the Parties. Cingular may provide written notice of rejection (with detailed reasons for said rejection) or acceptance within the mutually agreed upon Acceptance Testing schedule from the date the
Deliverable(s) are submitted by Infospace. 
  

	 	•	 	 Following the date of delivery of a Deliverable(s) in commercial ready form (“Commercial Ready Delivery Date”), unless otherwise
mutually agreed, Infospace and Cingular, prior to the beginning of test execution, will mutually agree to the following: 

  

	 	•	 	 Schedule of test execution 

  

	 	•	 	 Scope of test execution 

  

	 	•	 	 Bug / Feature triage process 

In the event that agreed schedule must change, Infospace and Cingular will review the impact from a schedule, scope and cost perspective
and will negotiate a new agreement associated with the particular Deliverable. 
  

	 	•	 	 Following the Deliverable Acceptance Date, Infospace will commercially release the Deliverable at a mutually agreed time.

  

	 	•	 	 The “Deliverable Acceptance Date” for such Deliverable(s) will be the earlier of (a) Cingular’s commercial release of such
Deliverable(s) to its general customer base or (b) the date of Cingular’s written notification to Infospace that Infospace has completed, to Cingular’s reasonable satisfaction, changes and bug fixes identified by Cingular and Cingular
has accepted the Deliverable as being ready for commercial launch, with such acceptance not being unreasonable withheld. If applicable, Cingular shall remit payment in full to Infospace for the new Deliverable following the Deliverable Acceptance
Date and subsequent receipt of an invoice, in accordance with Section 5.1. If a Deliverable is accepted and payment remitted, Infospace agrees to use commercially reasonable efforts during the Term to remedy any known bugs/defects contained in
such Deliverable, at no additional charge to Cingular, based on a mutually agreed upon schedule. In the event Cingular rejects a Deliverable, Infospace shall resubmit such Deliverable for acceptance within thirty (30) days of the initial
rejection by Cingular. If the re-submitted Deliverable(s) do not conform to the applicable specifications or acceptance criteria, Infospace will have thirty (30) days to fix the Deliverable(s) and resubmit. If the Deliverable(s) resubmitted for
a second time does not conform to the applicable specifications or acceptance criteria, Cingular shall have the right to the following: 

  

	 	•	 	 (i) if agreed to by Infospace, extend the period for Infospace to submit conforming Deliverable(s), or 

 

 48 

 EXHIBIT D – CHANGE REQUEST AND ACCEPTANCE TEST PROCESS 

 

	 	•	 	 (ii) terminate the applicable Work Order, in whole or in part with respect to certain feature, and require that Infospace promptly refund all payments
previously made to Infospace by Cingular for such nonconforming Deliverable(s). 

 In the event that Cingular
rejects a Deliverable and terminates a Work Order (or portion thereof), Cingular shall have the right to retain any materials that constitute Cingular Customized Work Product (see Exhibit L) related to the nonconforming Deliverable(s), provided that
Cingular pays a reasonable amount for such materials. Cingular shall promptly return to InfoSpace all materials related to such nonconforming Deliverable(s) that do not constitute Cingular Customized Work Product. 

If Cingular has not accepted (which acceptance shall not be unreasonably withheld) the Deliverable(s) within fifteen (15) business
days following the completion of all bug fixes by InfoSpace, Cingular will deliver a comprehensive list of bug fixes that Cingular requires InfoSpace to carry out prior to Cingular’s acceptance of the Deliverable(s) for commercial launch, and
representatives of the parties will meet and negotiate in good faith to define a mutually-agreed timeline and set of acceptance criteria to be used by Cingular in making such acceptance. 

 

 49 

 EXHIBIT E – EXECUTIVE ORDERS AND FEDERAL REGULATIONS 

 

 Executive Orders and Federal Regulations 

Work under this Agreement may be subject to the provisions of certain Executive Orders, federal laws, state laws, and associated regulations governing
performance of this contract including, but not limited to: Executive Order 11246, Executive Order 11625, Executive Order 11701, and Executive Order 12138, Section 503 of the Rehabilitation Act of 1973 as amended and the Vietnam Era
Veteran’s Readjustment Assistance Act of 1974. To the extent that such Executive Orders, federal laws, state laws, and associated regulations apply to the work under this Agreement, and only to that extent, SUPPLIER (also referred to as
“SUPPLIER”) agrees to comply with the provisions of all such Executive Orders, federal laws, state laws, and associated regulations, as now in force or as may be amended in the future, including, but not limited to the following:

 1. EQUAL EMPLOYMENT OPPORTUNITY DUTIES AND PROVISIONS OF GOVERNMENT SUPPLIERS 

In accordance with 41 C.F.R.§60-1.4(a), the parties incorporate herein by this reference the regulations and contract clauses required by that
section, including but not limited to, SUPPLIER’s agreement that it will not discriminate against any employee or applicant for employment because of race, color, religion, sex, or national origin. The SUPPLIER will take affirmative action to
ensure that applicants are employed, and that employees are treated during employment, without regard to their race, color, religion, sex, or national origin. 

2. AGREEMENT OF NON SEGREGATED FACILITIES 

In accordance with 41 C.F.R.§60-1.8, SUPPLIER agrees that it does not and will not maintain or provide for its employees any facilities segregated
on the basis of race, color, religion, sex, or national origin at any of its establishments, and that it does not and will not permit its employees to perform their services at any location, under its control, where such segregated facilities are
maintained. The term “facilities” as used herein means waiting rooms, work areas, restaurants and other eating areas, time clocks, rest rooms, wash rooms, locker rooms and other storage or dressing areas, parking lots, drinking fountains,
recreation or entertainment areas, transportation, and housing facilities provided for employees; provided, that separate or single-user restroom and necessary dressing or sleeping areas shall be provided to assure privacy between the sexes.

 3. AGREEMENT OF AFFIRMATIVE ACTION PROGRAM 

SUPPLIER agrees that it has developed and is maintaining an Affirmative Action Plan as required by 41 C.F.R.§60-1.4(b). 

4. AGREEMENT OF FILING 

SUPPLIER agrees that it will file, per current instructions, complete and accurate reports on Standard Form 100 (EE0-1), or such other forms as may be
required under 41 C.F.R.§60-1.7(a). 
  

 50 

 EXHIBIT E – EXECUTIVE ORDERS AND FEDERAL REGULATIONS 

 

 5. AFFIRMATIVE ACTION FOR HANDICAPPED PERSONS AND DISABLED VETERANS, VETERANS OF THE
VIETNAM ERA. 
 In accordance with 41 C.F.R.§60-250.20, and 41 C.F.R.§60-741.20, the parties incorporate herein by this reference
the regulations and contract clauses required by those provisions to be made a part of government contracts and subcontracts. 

6. Executive Order 13201 Compliance 

In accordance with 29 C.F.R. Part 470.2(b) the parties incorporate by reference the regulations and contract clauses required by those provisions to be
made a part of covered subcontracts and purchase orders and SUPPLIER agrees to comply with the provisions of 29 CFR Part 470. 

7. UTILIZATION OF SMALL, SMALL DISADVANTAGED AND WOMEN-OWNED SMALL BUSINESS CONCERNS 

As prescribed in 48 C.F.R., Ch. 1, 19.708(a): 

(a) It is the policy of the United states that small business concerns, small business concerns owned and controlled by socially and
economically disadvantaged individuals and small business concerns owned and controlled by women shall have the maximum practicable opportunity to participate in performing contracts let by any Federal agency, including contracts and sub-contracts
for systems, assemblies, components, and related services for major systems. It is further the policy of the United States that its prime SUPPLIERs establish procedures to ensure the timely payment amounts due pursuant to the terms of the
subcontracts with small business concerns, small business concerns owned and controlled by socially and economically disadvantaged individuals and small business concerns owned and controlled by women. 

(b) The SUPPLIER hereby agrees to carry out this policy in the awarding of subcontracts to the fullest extent consistent with efficient
contract performance. The SUPPLIER further agrees to cooperate in any studies or surveys as may be conducted by the United States Small Business Administration or the awarding agency of the United States as may be necessary to determine the extent
of the SUPPLIER’s compliance with this clause. 
 (c) As used in this contract, the term small business concern shall mean
a small business as defined pursuant to section 3 of the Small Business Act and relevant regulations promulgated pursuant thereto. The term small business concern owned and controlled by socially and economically disadvantaged individuals shall mean
a small business concern which is at least 51 percent unconditionally owned by one or more socially and economically disadvantaged individuals; or, in the case of any publicly owned business, at least 51 percent of the stock of which is
unconditionally owned by one or more socially and economically disadvantaged individuals; and (2) whose management and daily business operations are controlled by one or more such individuals. This term also means small business concern that is
at least 51 percent unconditionally owned by an economically disadvantaged Indian tribe or Native Hawaiian Organization, or a publicly owned business having at least 51 percent of its stock unconditionally owned by one of these entities which has
its management and daily business controlled by members of an economically disadvantaged Indian tribe or Native Hawaiian Organization, and which meets the requirements of 13 CRF part 124. The SUPPLIER shall presume that socially and economically
disadvantaged individual include Black Americans, Hispanic Americans, Native Americans, Asian-Pacific Americans, Subcontinent Asian Americans, and other minorities, or any other individual found to be disadvantaged by the Administration pursuant to
section 8(a) of the Small business Act. The SUPPLIER shall presume that socially and economically disadvantaged entities also include Indian Tribes and Native Hawaiian Organizations. 

 

 51 

 EXHIBIT E – EXECUTIVE ORDERS AND FEDERAL REGULATIONS 

 

 (d) The term “small business concern owned and controlled by women” shall mean
a small business concern (i) which is at least 51 percent owned by one or more women, or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women, and (ii) whose management and
daily business operations are controlled by one or more women; and 
 (e) SUPPLIERs acting in good faith may rely on written
representations by their sub-SUPPLIERs regarding their status as a small business concern, a small business concern owned and controlled by socially and economically disadvantage individuals or a small business concern owned and controlled by women.

 8. SMALL, SMALL DISADVANTAGED AND WOMEN-OWNED SMALL BUSINESS SUB-CONTRACTING PLAN. The sub-SUPPLIER will adopt a plan
similar to the plan required by 48 CFR Ch. 1 at 52.219-9. 
  

 52 

 EXHIBIT F – ATTRIBUTION 

 

 The following sample screen shot depicts the proportionate size and location of
attribution (“Powered by InfoSpace”) on the PC Pages (HTML). 

 

 

  

 53 

 EXHIBIT F – ATTRIBUTION 

 

 

 

  

 54 

 EXHIBIT F – ATTRIBUTION 

 

 The following sample screen shot depicts the attribution (“Powered by
InfoSpace”) on the Mobile Pages in WML format. 

 

 

  

 55 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

									
			
	1.	  	General Information	  	59
				
		  	1.1.	  	Purpose	  	59
					
		  	1.2.	  	Scope	  		  	60
				
		  	1.3.	  	Out of Scope	  	60
			
	2.	  	Responsibilities and Services	  	60
				
		  	2.1.	  	Infospace Responsibilities	  	61
				
		  	2.2.	  	Infospace Carrier Care	  	61
					
		  		  	2.2.1.	  	Infospace Support Services	  	62
					
		  		  	2.2.2.	  	PC Pages Support	  	62
				
		  	2.3.	  	Cingular Responsibilities	  	62
			
	3.	  	Service Performance Objectives	  	63
					
		  		  	3.1	  	Service Availability	  	63
					
		  		  	3.2	  	Service Latency	  	63
					
		  		  	3.3	  	Legacy Components Supporting M3	  	64
					
		  		  	3.4	  	Alarming & Monitoring	  	64
					
		  		  	3.5	  	Third-Party Content Providers	  	64
			
	4.	  	Incident Management	  	65
				
		  	4.1.	  	Incident Resolution Responsibilities	  	65
					
		  		  	4.1.1.	  	Cingular Contact Information	  	65
					
		  		  	4.1.2.	  	Cingular Responsibilities	  	66
					
		  		  	4.1.3.	  	Incident Handling and Updates	  	67

  

 56 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

									
	 	  	 	  	4.1.4.	  	Technical Bridge and Executive Bridge	  	 69

					
		  		  	4.1.5.	  	Escalation Procedures	  	70
				
		  	4.2.	  	WAP Handsets for Incident and Problem Management	  	71
			
	5.	  	Incident Reporting Process	  	72
				
		  	5.1.	  	Communicating Incidents	  	72
					
		  		  	5.1.1.	  	Mandatory Information for Incident Reporting	  	72
			
	6.	  	Infospace Reports	  	73
				
		  	6.1.	  	Post Mortem Reports	  	73
				
		  	6.2.	  	Service Level Reporting	  	73
				
		  	6.3.	  	Open Issues List Reporting	  	74
			
	7.	  	Change Control Management (CCM)	  	75
				
		  	7.1.	  	Planned Maintenance by Infospace	  	75
					
		  		  	7.1.1.	  	Service Interruptions and Advanced Notification Requirements	  	75
					
		  		  	7.1.2.	  	Communications Related to Planned Maintenance	  	75
					
		  		  	7.1.3.	  	Canceling Planned Service Interruptions	  	75
					
		  		  	7.1.4.	  	Restrictions Associated with Cingular’s Cancellation	  	76
					
		  		  	7.1.5.	  	Planned Service Interruptions by Cingular	  	76
					
		  		  	7.1.6.	  	Unplanned Service Interruptions by Cingular	  	76
					
		  		  	7.1.7.	  	Splash Page During Maintenance	  	76
				
		  	7.2.	  	Capacity Planning Forecasts	  	77
			
	8.	  	Financial Consequences of Non-Performance	  	77
				
		  	8.1.	  	Financial Consequences for Failure to Meet Service Objectives	  	77
				
		  	8.2.	  	Service Availability	  	78
				
		  	8.3.	  	Service Latency	  	78
				
		  	8.4.	  	Financial Consequences for Non-Performance Related to Incident Resolution	  	79
				
		  	8.5.	  	Financial Consequences for Past Due Monthly Service Level Report	  	79

  

 57 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

					
	Appendix A – Contact & Escalation List	  	81
		
	Appendix B – Maintenance Request Worksheet	  	82
		
	Appendix C – Incident Notification	  	83
		
	Appendix D – SLA Monitoring Requirements	  	84
		
	Appendix E – SLA Penalty Calculation Model	  	85

  

 58 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

					
			
	1.	  	General Information	  	
			
	1.1.	  	Purpose	  	
		
	The purpose of this document is to identify the levels of service that will be maintained by Infospace and Cingular and to provide this information to Operations
personnel responsible for the support of the Services.	  	

  

 59 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

	1.2.	Scope 

 This Service Level Agreement (SLA)
describes the basic level of service that will be provided by Infospace in its support of the delivery of the Services to Cingular. This agreement describes the requirements for the following: 

 

	 	a)	support and maintenance of all Infospace and third-party hardware and software for the Services 

 

	 	b)	7x24x365 support and response requirements for support calls; 

  

	 	c)	fixes, patches, and minor enhancements; 

  

	 	d)	new software releases that contain fixes to defects in production feature functionality; and 

 

	 	e)	on-site resources to support acceptance testing, trouble shooting, and system upgrades. 

This SLA also defines requirements for response (including email, telephone, remote, and on-site) and resolution timeframes related to
Severity 1, Severity 2, and Severity 3 incidents, as well as non-performance financial penalties which will be owed to Cingular for failures to meet certain obligations defined herein. 

This document also defines expectations relating to: 
  

	 	•	 	 Infospace and Cingular Responsibilities with respect to the Services 

 

	 	•	 	 Service Performance Objectives 

  

	 	•	 	 Incident Management 

  

	 	•	 	 Incident Reporting Process 

  

	 	•	 	 Operational Reports 

  

	 	•	 	 Change Control Management 

This document should be used as a reference for Cingular’s Network Operations and its contracted affiliates and Infospace in support of the
Services. It provides the framework for surveillance, isolation, analysis, and resolution of problems related to the Services. 
 As a means to
ensure the highest level of accuracy and efficiency for both Cingular and Infospace, this SLA supersedes all existing Service Level Agreements relating to the Services. 

For a complete list of the Services that are subject to this SLA, see the SLA Monitoring Requirements (Appendix D) below.

  

	1.3.	Out of Scope 

 The
following items are deemed to be outside the scope of this SLA; however, both parties will make a good faith effort to establish the following independently from this SLA. 

*** 
  

	2.	Responsibilities and Services 

 This
Section 2 describes Infospace’s support responsibilities with respect to the Services, and the corresponding responsibilities of Cingular. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 60 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

	2.1.	Infospace Responsibilities 

 Infospace
will provide day-to-day service operations, maintenance and administration in support of the Services that are within Infospace’s Span of Control, as described below. 

Span of Control is defined as those areas of functionality that are under the direct control of Infospace. This includes functionality that is provided
by external vendors or suppliers with whom Infospace has a contractual relationship, including feeds from providers of Infospace Sourced Content. 

It is the intention of Infospace to expeditiously remedy incidents that have been identified either internally by Infospace or Cingular. Corrective
action by Infospace assumes that the incident is within its Span of Control and Cingular has provided all relevant information, if available, to Infospace. See the section entitled Mandatory Information for Incident Reporting for required
reporting information. 
 Infospace will pursue the resolution of an incident with outside vendors provided Infospace has a contractual
arrangement with the vendor. During the resolution period, Infospace will issue updates to Cingular pursuant to the severity of the incident, as described later in this document. 

Any third party content provider contracted directly by Cingular is not a party to this agreement. Any loss of content from such providers is outside of
Infospace’s Span of Control. 
  

	2.2.	Infospace Carrier Care 

The Infospace Carrier Care Support Services team is an interface between Cingular’s Level 2 Support Group (Cingular’s
non-customer facing group) and Infospace for support of services provided by Infospace. This arrangement provides Cingular with access to a single point of contact for reporting incidents, receiving updates and escalation. Table 1 provides
the Infospace Carrier Care hours of operation and contact information. A complete list of all contacts is also shown in Appendix A. These contacts are to be contacted per the escalation procedures outlined in Section 3.

  

			
		
	 Hours of

Operation
	  	24 hours a day, 7 days a week and 365 days a year (7/24/365)
		
	Contact Phone Number	  	***
		
	Email Address	  	***

 Table 1, Infospace Carrier Care Contact
Information 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commisson.

  

 61 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

	2.2.1.	Infospace Support Services 

The following list identifies services that are offered by Infospace Support Services to Cingular: 

 

	 	•	 	 Telephone and email support for incident resolution 

  

	 	•	 	 Advisory Bulletins 

  

	 	•	 	 Notification of planned maintenance activities 

  

	 	•	 	 Post Mortem Reports for Severity 1 (SEV1) and recurring incidents classified as Severity 2 (Sev2) including a Root Cause Analysis (RCA) upon request.
*** 

  

	2.2.2.	PC Pages Support 

 As applicable, the PC
Pages related Services will operate on browsers that are HTML 4.0 Compliant, specifically, Internet Explorer (IE) 5.0 and above. Infospace will make commercially reasonable efforts to support other browsers that demonstrate significant market
presence. 
  

	2.3.	Cingular Responsibilities 

Cingular will provide support for Incident Management as detailed in Section 4. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 62 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

	3.	Service Performance Objectives 

  

	3.1	Service Availability 

 Service
Availability (SA) is defined as the amount of time the service is up excluding planned Maintenance and Cingular caused outages, computed as: 

*** 
 The above
calculations allow a weighting for partial outages and degraded service, such that only the fraction of Users denied service contributes to negative Service Availability. 

 

	3.1.1	 Service Availability Target 

Infospace shall provide an overall system service availability of *** for all Services listed in the SLA Monitoring Requirements (Appendix D)
below, measured at no less than the frequency shown in Appendix D and reported at monthly intervals as described in Section 6.2 below. This measurement excludes downtimes caused by Cingular and service interruptions due to planned
maintenance approved in advance by Cingular. 
  

	3.2	Service Latency 

 User requests for
Services shall be fulfilled in accordance with Table 2 below for each calendar month. This includes delivery of all bytes of the response (content plus protocol overhead) that Infospace controls (i.e. service requests and subsequent requests for
which the browser’s URL target is hosted by Infospace). 
 InfoSpace will achieve the latency targets set forth in Table 2 below on the
schedule set forth in Table 2. The parties agree to review such latency targets from time to time during the Term and to assess whether to adjust the latency. Unless otherwise mutually agreed, these are the targets for penalties as set forth in
Section 8.3. 
  

									
	 ***
	  		  		  		  	

 Table 2, Latency Target Ramp 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 63 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

 These requirements are specific to the portion of end to end Latency incurred within the
Infospace’s Span of Control and will be measured from the secure network nearest the Infospace border router. The design of latency monitoring infrastructure will ensure appropriate components of the request and response are adequately
measured. The implementation of latency monitoring infrastructure will include the deployment of a separate and specific server(s) for the purpose of monitoring and fault management. The latency introduced by the GPRS network, the WAP Gateway and
other elements of the Cingular Network are excluded from the latency measurements described above. 
  

	3.3	Legacy Components Supporting M3 

 The
following Legacy Services will not be held to the Service Availability as noted above but will meet the legacy Service Availability of *** on a monthly basis as set forth below: 

*** 
 Service Availability (SA)
is defined as the amount of time the service is up excluding planned Maintenance and Cingular caused outages, computed as: 

*** 
 The above
calculations allow a weighting for partial outages and degraded service, such that only the fraction of Users denied service contributes to negative Service Availability.*** 

3.4 *** 
  

	3.5	Third-Party Content Providers 

 Infospace
will be responsible for the performance, service availability and service latency of all providers of Infospace Sourced Content with whom Infospace has a contract. Where such content provider contracts exist, Infospace will perform appropriate
alarming, monitoring and fault management to ensure that performance of these providers fully supports the service objectives defined in this SLA. Infospace will also identify those content providers to Cingular and provide notification of changes
to such contractual relationships no less than 30 days in advance of such changes becoming effective. 
 Expectations for processing of third
party content feeds as set forth in Appendix D are as follows: For streaming content (sports scores and stock quotes) and breaking news, all received content must be processed and published a maximum of *** For all other content feeds that
are updated at least once a day, content must be processed and published within a maximum of *** For all other content feeds (those updated less frequently than once per day), the content must be processed and published as soon as possible, and will
at all times display content for the current day. 
 Infospace will also provide monthly reporting of service interruptions, availability
measures and other data for contracted providers of Infospace Sourced Content in accordance with Section 6. 
 In addition,
Infospace will be responsible for all degradations and service impacting issues affecting the Services that are caused by providers of Infospace Sourced Content from an Infospace SLA performance perspective. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission

  

 64 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

	4.	Incident Management 

  

	4.1.	Incident Resolution Responsibilities 

Incident resolution requires teamwork between Infospace and Cingular. A key element in this teamwork approach is Cingular’s understanding of the User
service(s) offered by Infospace. 
 All Cingular identified incidents concerning failures of the Services that cannot be solved by Cingular
representatives will be reported to Infospace Carrier Care Support Services, pursuant to the Reporting Process procedures outlined below. Cingular will assign a Severity Level per Table 4. If Infospace disagrees with the Severity assignment,
both parties will negotiate in good faith after the resolution of the incident but all restoration will proceed based upon Cingular’s initial Severity assignment. 

Any reported incident that is caused by a failure that is outside Infospace’s Span of Control and not directly related to its delivery of a
subscriber service will be returned to Cingular with an appropriate explanation. Should Infospace determine that an incident being worked by Infospace Carrier Care Support Services is within Cingular’s control, the incident will be closed and
returned to Cingular for proper resolution. 
  

	4.1.1.	 Cingular Contact Information 

In order for Infospace Carrier Care to effectively resolve Incidents, it is necessary for Infospace to have an accurate list of
Cingular’s designated key personnel. This information will be exchanged between the two parties and updated as changes warrant. Appendix A shows the type of contact information required, showing the current contacts at the Effective
Date. This data will be maintained and updated by the two parties outside of this SLA document. 
  

							
	 Cingular
	  	 Hours of Operation
	  	 Role
	  	 Phone/Email

	 NSD National

Operations

Center
	  	24 x 7 x 365	  	Incident Management and Emergency Maintenance	  	***
				
	 MMS External

Partner Ops
	  	8:00 am – 5:00 pm PT Monday – Friday	  	Incident Root Cause Analysis, Change Management, Performance Reports and Tier 2 Support	  	***
				
	 Change

Management
	  	8:00 am – 5:00 pm PT Monday – Friday	  	Maintenance Notification – all maintenance	  	***

 Table 3, Cingular Contact Information 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission

  

 65 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

	4.1.2.	 Cingular Responsibilities 

The following section identifies the responsibilities of Cingular as it relates to this Service Level Agreement. 

 

	4.1.2.1.	 General Responsibilities 

  

	 	•	 	 Acts as the primary and direct contact with the User. 

 

	 	•	 	 Answers simple questions and resolves minor issues such as resetting passwords or creating new User accounts. 

 

	4.1.2.2.	 Incident Responsibilities 

  

	 	•	 	 Creates a trouble ticket that clearly states the problem after gathering all pertinent information about the incident including name, User number,
password and any other additional information that is important to resolution of the incident. 

  

	 	•	 	 Records any subsequent conversation with the User relative to the incident in the same trouble ticket. 

 

	 	•	 	 “Owns” the resolution of an incident by coordinating its resolution within Cingular operational and technical environment and with Infospace
or its designees. 

  

	 	•	 	 Resolves the incident with the User or determines that the capability is outside the scope of current functionality. 

 

	 	•	 	 Explains the resolution of the incident to a technical peer or is capable of targeting the root technical problem for resolution.

  

	 	•	 	 Describes the incident in technical terms to an engineer or developer who is responsible for resolution of the incident. 

 

	 	•	 	 Explains the resolution of particular escalated trouble tickets to Cingular’s internal staff members when such an explanation may have the
potential for reducing the volume and categories of escalated trouble tickets. 

  

	4.1.2.3.	 Service Responsibilities 

  

	 	•	 	 Uses and understands all Infospace service features that are available to the User. 

 

	4.1.2.4.	 Technical Responsibilities 

  

	 	•	 	 Understands and is knowledgeable about problems that may arise during service usage. 

 

	 	•	 	 Understands and is knowledgeable with respect to functionality of supported handset models. 

 

	 	•	 	 Understands and is knowledgeable with email notification systems, the Internet and the World Wide Web. 

 

	 	•	 	 Understands and is knowledgeable with its network operations and is capable of discerning whether an incident is internal to its internal operations
before identifying the incident as a trouble ticket for Infospace. 

  

 66 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

	4.1.3.	 Incident Handling and Updates 

The Infospace Carrier Care Support Services group of Infospace will coordinate incident isolation, testing and repair work within
Infospace and all contracted third party systems that are within Infospace’s Span of Control. During the incident isolation and troubleshooting process, Infospace Carrier Care Support Services will communicate incident resolution progress with
Cingular based upon the times specified in Table 4. Additionally, Infospace Carrier Care Support Services will proactively inform Cingular when an issue or condition arises that may cause potential system anomalies and be a potential source
for the creation trouble tickets. 
  

 67 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

							
	 Infospace Incident Level
	  	 Description
	  	 Update
Method
	  	 Update

Objectives

	 Severity 1
 (Sev1)

Cingular SIR1
	  	  
 Severity 1 problems are conditions that render
the service inoperative and the inability to use the service has a critical effect on operations. The condition is generally characterized by complete system failure and requires immediate restoration. Examples of this incident level being attained
include:
  

•   A complete outage of critical service(s)

 
 •   Loss of service or
functionality feature that affects *** or more of subscribers
  

•   A recurring anomaly impacting critical service(s).

 
 •   Inability to
provision a service.
	  	Email and phone	  	 First response within ***
  

First Update within ***
  

Subsequent updates *** or upon change in status.
  

Infospace will update Cingular with the information outlined in Appendix C.

				
	 Severity 2
 (Sev2)

Cingular SIR2
	  	  
 Severity 2 problems are conditions under which
the service is partially inoperative, but is still usable. The inoperative portion of the service restricts operations but has a less critical effect than a Severity 1 condition. Examples of this incident level being attained include:

 
 •   Loss of service
and/or functionality that affects *** to *** of the subscribers.
  

•   Loss of the ability to utilize some aspect of product features or
functionality.
	  	Email or phone	  	 First response within ***
  

First update within ***
  

Subsequent updates every *** or upon change in status.
  

Infospace will update Cingular with the information outlined in Appendix C.

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 68 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

							
	 Severity 3
 (Sev3)

Cingular SIR3
	  	  
 Severity 3 problems are generally non-service
affecting conditions under which the service is usable and either has no material affect on operations or has very limited affect on operations. The condition is not critical to overall operations, and does not severely restrict such operations.
Examples of this incident level being attained include:
  

•   A minor degradation of the service that affects *** or less of the
subscribers.
  

•   Non-service impacting intermittent system faults.

 
 •   Loss of resources /
capacity / traffic measurement function.
  

•   Loss of reporting functionality.

 
 •   Invalid measurement
data.
  
 •   Web
interface defects that have little or no impact on a User’s ability to utilize service features and functions.
	  	Email	  	 First response within ***

First update within ***
 Subsequent updates ***
as agreed between the two parties.
 Infospace will update Cingular with the information outlined in Appendix C.

Table 4, Incident Handling Notification Timetable 
  

	4.1.4.	 Technical Bridge and Executive Bridge 

During the resolution of a service affecting incident, Cingular may establish a Technical Bridge and/or an Executive Bridge for any
Incident. Infospace shall join the Technical Bridge upon *** notice from Cingular for Severity 1 issues as noted in Table 5 below. These bridges are used for NOC-to-NOC communication, troubleshooting, triage and escalation. Unless otherwise notified
by Cingular, a Technical Bridge or Executive Bridge will be established as follows: 
  

							
	 Action
	  	 Sev 1
	  	 Sev 2
	  	 Sev 3

	Technical Bridge	  	 *** when reasonably possible)
	  	 *** (or sooner upon request from Cingular)
	  	 *** (or sooner upon request from Cingular)

				
	 Executive Bridge
	  	***	  	***	  	N/A

 Table 5, Timelines for Technical
and Executive Bridges 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commisson.

  

 69 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

	4.1.5.	    Escalation Procedures 

  

	4.1.5.1.	 Infospace Internal Escalation 

Escalation procedures are in place at Infospace to manage the resolution of incidents when they occur. If a Severity 1 (Sev1) incident is
not resolved within *** of when Infospace was made aware of the problem, the incident will be escalated within Infospace to the dedicated Manager of Production Operations, who will drive escalation and resolution of the incident within
Infospace’s Operations and Engineering groups, and ensure that Cingular is kept updated with the incident resolution process. The appropriate Business Development person will also be informed of the occurrence and status of any Sev1 incident.

 If the Sev1 incident has not been resolved by the Infospace & Cingular NOC teams within 1 hour, the Director of
Commercial Operations will become directly involved with driving the incident to resolution and communicating with the appropriate Cingular personnel. The status of the incident will also be communicated to senior management within Infospace.

  

	4.1.5.2.	 Cingular Escalation to Infospace 

In the event that Infospace does not respond to Cingular within the times shown in Table 4, Cingular can request that the incident
be escalated to the next level, based on the contact information shared between the two companies (see Appendix A for a list of names that are current as of time of the Effective Date). All escalation requests must be initiated through the
7x24 contact information provided in Table 1, and not to the individual directly. Only in the event that the 7x24 representative does not escalate within *** of Cingular’s request, should the appropriate Infospace individual be contacted
directly. Cingular must verify that escalation has not taken place prior to calling any Infospace employee directly. 
 For the
purposes of clarification, Table 6 provides escalation timelines for Severity 1 and 2 incidents, based on time after the incident was reported. Severity 3 incidents seldom require escalation but in the event that Cingular believes that
Infospace is not addressing the incident in a timely manner, the parties can mutually agree to elevate the priority of the incident, and treat it as a Severity 2 incident. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission

  

 70 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

							
	 Escalation Level
	  	 Escalation Contact
	  	 Severity 1
	  	 Severity 2

	Level 1	  	Carrier Specialist	  	***	  	***
				
	Level 2	  	Manager – Production Operations	  	***	  	***
				
	Level 3	  	Director – Commercial Operations	  	***	  	***

 Table 6, Escalation Timetable 

 

	4.1.5.3.	 Additional Escalation Information 

Infospace and Cingular will ensure that any additional processes that are required to ensure the smooth escalation of incidents within
each organization are clearly communicated to one another in writing, so that the escalation processes within each organization and between the two organizations are clearly understood by both parties. 

Infospace and Cingular will exchange the names and contact information of the personnel who need to be kept informed of progress during
the escalation process in Appendix A. Both parties are responsible for ensuring that the contact information is updated and exchanged when circumstances warrant. This information will not be updated and kept current as part of this SLA, but
will need to be maintained separately by the two parties outside of this document. 
  

	4.2.	WAP Handsets for Incident and Problem Management 

In order for Infospace to provide the most effective level of support, Cingular agrees to provide Infospace with two (2) testing
units for each device type specifically for supporting Incident and Problem Management. Each such device shall be appropriately provisioned and have a valid account and password as to properly access the Cingular network. Each such unit shall be the
GA (general availability) version of the handset and should be supplied to Infospace no less than 30 days prior to launch. 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 71 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

	5.	Incident Reporting Process 

  

	5.1.	Communicating Incidents 

Cingular will communicate incidents to Infospace in the following manner: 

 

	 	•	 	 Phone call to Infospace NOC or sends a trouble ticket to Infospace via email using the email address of ***  

 

	 	•	 	 Infospace sets the initial classification of their internal trouble ticket according to the Cingular notification (see “Mandatory
Information” below), unless otherwise agreed between Infospace and Cingular. 

  

	 	•	 	 Infospace will generate a single response for each trouble ticket that is received from Cingular, to confirm receipt of the incident report.

  

	5.1.1.	 Mandatory Information for Incident Reporting 

For each Cingular originated incident, Cingular will make every effort to provide as much information to Infospace that will facilitate
timely problem determination and resolution. Upon notification of the incidents, the required information will be verified. When Infospace has received sufficient information, Infospace will begin resolving the incident and provide feedback to
Cingular as described above in Section 5.1 Communicating Incidents. 
 Cingular will use best efforts to provide
Infospace the following information via email for all reported incidents as required: 
  

	 	•	 	 Reference number assigned by Cingular. 

  

	 	•	 	 Infospace Service being used. 

  

	 	•	 	 System Identity number (usually phone number). 

  

	 	•	 	 Time and date of the transaction in question. 

  

	 	•	 	 Description of the incident. 

  

	 	•	 	 Severity of the incident or problem. 

  

	 	•	 	 List of specific steps to reproduce the problem if possible 

 

	 	•	 	 List of those actions taken by Cingular to verify the problem and that Cingular has attempted to resolve the incident. 

 

	 	•	 	 Other comments to provide additional information as needed. 

 

	 	•	 	 All communications that include references to time should be expressed using a 24-hour clock format and should always utilize and reference PST as the
standard time zone. 

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 72 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

	6.	Infospace Reports 

  

	6.1.	Post Mortem Reports 

 The purpose
of the Post-Mortem Report is to outline the known information regarding the incident and possible root causes and to summarize the incident resolution timeline. If known, it will also identify corrective actions to prevent its reoccurrence.
Infospace will create a Post-Mortem Report and provide such report to Cingular per Section 2.2.1. 
  

	6.2.	Service Level Reporting 

 Each
month, Infospace will provide Cingular with a “Monthly Service Level Report” indicating the service performance for the Services for the previous month (see SLA Monitoring Requirements (Appendix D) below for detailed list of
Services associated with this SLA). This report will contain performance reporting for the service performance objectives listed in Appendix D and a summary of the weekly incident response reports described in Section 6.3 for such
month. 
 Infospace shall supply the Monthly Service Level Report no later than the tenth business day of the month following
the immediately preceding month. It is agreed that Infospace will work towards publishing the Monthly Service Level Report on the sixth business day starting 6 months from the initial launch of Services. 

The Monthly Service Level Report shall include, among other things, the following information related to service availability for the
Services listed in Appendix D: 
  

	 	•	 	 Total minutes in the current month 

  

	 	•	 	 Total available minutes for the reported month for each Service 

 

	 	•	 	 Calculated Service Availability, presented as a percentage for each Service 

 

	 	•	 	 Target Service Level Availability for each Service 

  

	 	•	 	 Variance from Target Service Level for each Service 

  

	 	•	 	 Overall Service Level Availability for the Services 

The Monthly Service Level Report shall include, among other things, the following information related to latency for the Services listed
in Appendix D: 
 *** 

The Monthly Service Level Report shall also include, among other things, the following information for the Services listed in Appendix
D: 
  

	 	•	 	 Appropriate performance metrics related to processing of
3rd party content feeds 

 

	 	•	 	 Overall Service Level Availability for Infospace contracted Third Party Content Providers 

 

	 	•	 	 Detailed log of all service impacting incidents for the month 

 

	 	•	 	 Service levels achieved for Users of the PC Pages and Users of the Phone Pages as listed in Section 3.3 above.

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 73 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

	6.3.	Open Issues List Reporting 

Infospace shall provide a weekly Open Issues Report, to be reviewed jointly with Cingular during the weekly Operations Call. Both parties
agree to periodically review the appropriateness of the frequency of the Open Issues Report and Operations Call. This report shall include the following information: 
  

	 	•	 	 Outage report including; 

  

	 	•	 	 Ticket Number 

  

	 	•	 	 Start time 

  

	 	•	 	 End time 

  

	 	•	 	 Resolution 

  

	 	•	 	 Severity level 

  

	 	•	 	 Impact 

  

	 	•	 	 Number of Reported Issues and brief summary of the issues 

 

	 	•	 	 Date that each Reported Issue was opened 

  

	 	•	 	 Current Reported Issue status, and if resolved, the date of the resolution. 

 

	 	•	 	 Total number and description of unresolved issues. 

 

 74 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

	7.	Change Control Management (CCM) 

  

	7.1.	Planned Maintenance by Infospace 

Infospace will ensure that any planned maintenance events under its Span of Control will be executed in a well-coordinated manner. Proper
execution includes notification to Cingular by Infospace Carrier Care Support Services. 
  

	7.1.1.	 Service Interruptions and Advanced Notification Requirements 

Infospace will provide Cingular with *** advance notice (via email) of all planned maintenance activities resulting or potentially
resulting in service interruptions that will have a direct impact on the Services unless otherwise mutually agreed by the parties. Infospace may assume that Cingular accepts the scheduled maintenance unless Infospace is advised via email within ***
the time of the planned event. 
 Unless otherwise arranged, Infospace will perform planned service interruptions from *** or as
otherwise communicated between the two parties. 
 *** 

Please Note: *** Any Infospace unplanned system downtime resulting from a Cingular maintenance activity or
otherwise required on account of Cingular’s action(s) or inaction(s), will not be counted against the Infospace SLA service measures from the time the requested maintenance activity was scheduled through the end of that month. The outage and/or
service degradation must be directly attributable to the Cingular maintenance activities or otherwise required on account of Cingular’s action(s) or inaction(s).  

 

	7.1.2.	 Communications Related to Planned Maintenance 

Infospace notification of planned maintenance will be communicated to Cingular through use of the Maintenance Request Worksheet shown in
Appendix B. Infospace will provide official notification to Cingular of the start and end of a planned maintenance activity via email to the contacts identified in Section 4.1.1. During all planned maintenance activities, Cingular
will establish a technical bridge for real time communication of status and progress, and Infospace will participate in that technical bridge unless otherwise agreed by both parties. 

 

	7.1.3.	Canceling Planned Service Interruptions 

In the event of a Cingular emergency, Cingular may cancel the planned service interruption. Cancellation by Cingular may occur only if
Cingular notifies Infospace within *** of the scheduled start time of the maintenance window. Any notification of cancellation must come directly from either an Operations Manager or Cingular Team Leader via voice notification by calling ***
for local or International calls), with a follow-up email that should be sent to: 
 *** 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission

  

 75 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

	7.1.4.	 Restrictions Associated with Cingular’s Cancellation 

In the event that Cingular cancels a maintenance activity planned by Infospace, as defined in Section 7.1.1 above, and the
parties are unable to mutually agree on an alternative schedule, Infospace will not be held to the SLA service measures from the time the requested maintenance activity was scheduled through the end of that month. The outage and/or service
degradation must be directly attributable to the postponed maintenance activities. 
 If an alternative schedule is agreed upon,
but a failure occurs between the originally approved maintenance window and the rescheduled maintenance window, Infospace will not be held to the SLA services measures for that related outage and/or degradation. 

 

	7.1.5.	 Planned Service Interruptions by Cingular 

Cingular will provide Infospace with advance notice (via email to ***) of all planned maintenance activities requiring support from
Infospace. Cingular will make every effort to provide *** advance notice and will provide at a minimum *** advance notice of such activities. Such planned activities will exclude changes to Infospace software and/or configurations as these would
require additional notice. 
  

	7.1.6.	 Unplanned Service Interruptions by Cingular 

Cingular will notify Infospace of any unplanned service interruptions via email to Infospace Carrier Care (***) as quickly as is
reasonably possible for Cingular. 
 Infospace will make all reasonable efforts to support Cingular in resolving the issue.
Infospace may charge its standard professional services fees for such efforts. 
  

	7.1.7.	 Splash Page During Maintenance 

The parties will cooperate to display a “splash page” during any planned or emergency maintenance that would otherwise result in
a TCP timeout from a WAP Gateway and other mutually agreed required maintenance activities requiring customer requests to be blocked whenever reasonably technically feasible. Such a page will be presented to users of both the wired and wireless web
access points, to inform them of temporary unavailability of the Services. Service of the splash page does not constitute availability, but is categorized as either planned or unscheduled service interruption (in accordance with
Section 7.1). Cingular will provide the static WML/xHTML content to be displayed in the “splash page”. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 76 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

	7.2.	Capacity Planning Forecasts 

 To
ensure the highest level of service, Infospace requires Cingular at least twice per year to provide a forecast estimating the growth of their customer base (3, 6, 9 and 12 months into the future) and likely service usage. This will allow Infospace
to plan the required resources to support the services for Cingular’s customers. If Cingular becomes aware of any material changes that would impact any forecast previously provided to Infospace (e.g., if Cingular has a special promotion plan
in which a high number of new customers are anticipated), Infospace must be given 30 days advance notice of any change in the forecast to prepare for such additional capacity. If Cingular fails to provide Infospace with such notice, Infospace will
not be held responsible for any failures to the performance objectives that could have been avoided had Infospace received such notice. A forecast provided pursuant to this section is only a forecast and is not a commitment on behalf of Cingular for
the forecasted amount. 
  

	8.	Financial Consequences of Non-Performance 

  

	8.1.	Financial Consequences for Failure to Meet Service Objectives 

The following sections define financial penalties for non-performance related to service objectives within the Infospace Span of Control.

 These non-performance penalties will apply commencing on the date of commercial launch of the Services. The total financial
penalties will be subject to the following Infospace revenue caps. 
  

							
	 Period

(start date adjusted based on

actual launch date)
	  	 Month
	  	 Cap
	  	 Max Net SLA Penalty After Cap

(based on min. M3 rev.)

	 ***
	  	***	  	***	  	***
				
	 ***
	  	***	  	***	  	***
				
	 ***
	  	***	  	***	  	***
				
	 ***
	  	***	  	***	  	***
				
	 ***
	  	***	  	***	  	***

 Table 7, Penalty Cap Phase-In
Schedule 
 For the purposes of the SLA, Infospace “Total Revenue” shall be calculated as follows: the sum of ***
for the applicable month. For further detail regarding the non-performance penalties described below, reference SLA Penalty Calculation Model (Appendix E) below. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 77 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

 For any month for which there is an Availability and a Latency penalty due for the same
period of time, Infospace shall be required to pay only the Availability penalty and the Latency penalty shall be waived when mutually agreed that there was a common or related cause. 

Infospace will deduct penalties for non-performance from the subsequent month’s invoice to Cingular for the Services. 

 

	8.2.	Service Availability 

  

	(a)	Service availability targets apply to Services provided to Cingular as described in the SLA Monitoring Requirements (Appendix D) below and will be reported as
required in Section 6 above. Notwithstanding the foregoing, non-performance penalties will apply solely to the WAP portions of the following Services: 

 

			
	 Service Area
	  	 Penalty Amount

(% of Total Revenue)

	 ***
	  	***
		
	 ***
	  	***
		
	 ***
	  	***
		
	 ***
	  	***

 Table 8, Service Availability
Penalty Calculation 
  

	(b)	Subject to Section 8.1, Infospace agrees to pay to Cingular service availability failure fees computed on a monthly basis, as a calculation of (i) plus (ii):

  

	***	

 Infospace will utilize
the most recent and relevant historical user data available for the purpose of determining the percentage of users impacted during periods of unavailability. 
  

	8.3.	Service Latency 

 Service latency
targets apply to Services provided to Cingular as described in Appendix D and will be reported as required in Section 6 above. Notwithstanding the foregoing, non-performance penalties will apply solely to the following portions of
the Services as further described in Appendix D: 
  

					
	***	 	***	 	***

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 78 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

 *** 

Table 9, Latency Penalty Calculation 

*** 
 Table 10, Latency Target Ramp 

 Subject to Section 8.1, Infospace agrees to pay to Cingular excessive latency fees based on performance according
to Table 10 above for each month of the SLA reporting period. In the event the monthly latency measurement for a particular Service Area listed in Table 9 above exceeds *** 

 

	8.4	*** 

  

	8.5	*** 

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 79 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

	9	Right to Terminate 

  

	(a)	Right to Terminate for Failure to Meet Monthly Service Availability Requirement. 

In the event that the monthly service availability target described in Section 3.1 is not met for the Service Areas
listed in Section 8.2 above in any three calendar months within any four month period during the Term, then, at the end of any such third failed month, Cingular shall have the right, in its sole discretion, to terminate the Agreement for cause
upon thirty (30) days prior written notice to Infospace or to provide Infospace notice of Cingular’s intent to develop a “Get Well Plan.” In the event that Cingular delivers a “Get Well Plan” notice, the parties will
use good faith efforts to agree to and execute on a plan for Infospace to remedy the applicable performance failures and meet the service availability target set forth in Section 3.1. Upon implementation of any such mutually agreed plan, a new
four month measurement period to determine compliance with the service availability requirement will commence. 
  

	(b)	Right to Terminate for Failure to Meet Latency Requirement. 

In the event that the latency requirement described in Section 3.2 is not met for the Service Areas listed in
Section 8.3 above in any three calendar months within any four month period, then, at the end of any such third failed month, Cingular shall have the right, in its sole discretion, to terminate the Agreement for cause upon thirty (30) days
prior written notice to Infospace or to provide Infospace notice of Cingular’s intent to develop a “Get Well Plan.” In the event that Cingular delivers a “Get Well Plan” notice, the parties will use good faith efforts to
agree to and execute on a plan for Infospace to remedy the applicable performance failures and meet the service latency target set forth in Section 3.2. Upon implementation of any such mutually agreed plan, a new four month measurement period
to determine compliance with the service availability requirement will commence. 
  

 80 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

 Appendix A – Contact & Escalation List 

Both parties are responsible for ensuring that the contact information is updated and exchanged when circumstances warrant. This
information will not be updated and kept current as part of this SLA, but will need to be maintained separately by the two parties outside of this document. 

Infospace Customer Care Contact Information *** 
  

			
	Single Point of Contact Name	  	Infospace Carrier Care
	Title	  	n/a
	Phone	  	***
	Email	  	***
		  	
	Second Level Contact Name	  	***
	Title	  	Manager – Production Operations
	Phone	  	***
	Email	  	***
		  	
	Third Level Contact Name	  	***
	Title	  	Director – Commercial Operations
	Phone	  	***
	Email	  	***

 Cingular Contact Information 

 

							
	 Cingular
	  	 Hours of Operation
	  	 Role
	  	 Phone/Email

	 NSD National

Operations Center
	  	24 x 7 x 365	  	Incident Management and Emergency Maintenance	  	***
				
	 MMS External

Partner Ops
	  	 8:00 am – 5:00 pm

PT Monday – Friday
	  	Incident Root Cause Analysis, Change Management, Performance Reports and Tier 2 Support	  	***
				
	 Change

Management
	  	 8:00 am – 5:00 pm

PT Monday – Friday
	  	Maintenance Notification – all maintenance	  	***

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 81 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

 Appendix B – Maintenance Request Worksheet 

This Maintenance Request Worksheet is be sent to: *** 

 

	1)	Title of Maintenance 

  

	2)	Brief Description of Maintenance 

  

	 	-	Scope and full description 

  

	 	-	Cingular service 

  

	3)	Maintenance Start Date & Time 

  

	4)	Maintenance End Date & Time 

  

	5)	Cingular Service Impact 

  

	 	-	Impact to Cingular internal & external customers 

  

	 	-	Explanation of Information Service unavailability 

  

	6)	Information Service Impact Assessment (within the scheduled window) 

 

	 	-	Duration in minutes 

  

	 	-	Estimated start/end time of Cingular service impact 

  

	7)	Risk Assessment 

  

	8)	Partner Maintenance Request Number 

  

	9)	Point of Contact 

  

	 	-	Name, telephone numbers 

  

	10)	Maintenance Install Team 

  

	11)	Update Schedule 

  

	 	-	Cancellation of Maintenance – as soon as possible 

  

	 	-	Start of Maintenance Window 

  

	 	-	Notify when Down Time begins 

  

	 	-	Notify when Information Service is restored (Down Time ends) 

  

	 	-	Notify of Problem 

  

	 	-	Maintenance runs outside window 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 82 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

 Appendix C – Incident Notification 

Incident Notification or Trouble Ticket (send to: *** 

 

	1)	Title of Incident 

  

	2)	Brief Description of Incident 

	 	-	Should include scope (Cingular service impacted) 

  

	3)	Start Date and Time 

  

	4)	Information Service Resolution Date and Time 

  

	5)	Duration of Outage 

  

	 	-	Provided at time of restoration 

  

	6)	Cingular Information Service Impact 

  

	 	-	Impact to Cingular End Customer 

  

	7)	Partner Ticket Number 

  

	8)	Partner Severity Level 

  

	 	-	Based on quantified Information Service impact 

  

	9)	Technical Action Take to Correct Incident 

  

	 	-	Steps taken to restore Information Service 

  

	10)	Initial Root Cause 

  

	 	-	Suspect root cause (brief) 

	 	-	Formal RCA for SIR 1 or chronic issues of lower severity 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 83 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

 Appendix D 

Cingular M3 SLA Monitor Requirements Summary 

*** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 84 

 EXHIBIT G – SERVICE LEVEL AGREEMENT 

 

 Appendix E—M3 SLA Penalty Calculation Model 

*** 
  

 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 85 

 EXHIBIT H – BUSINESS REQUIREMENTS TEMPLATE 

 

					
	

	 		  	  
 Project Name Here

 
 Business Requirements

 
 Date

 
 Version 1.0

 
 Developed by:

 
 Cingular Wireless

 
 5565 Glenridge Connector

 
 Atlanta, GA 30342

 

 86 

 EXHIBIT H – BUSINESS REQUIREMENTS TEMPLATE 

 

 Table of Contents 

 

			
	 1. Document Details
	  	88
		
	 Document History
	  	88
		
	 Project Team
	  	88
		
	 2. Overview & Objectives
	  	89
		
	 Scope
	  	89
		
	 Terminology
	  	89
		
	 Workflow
	  	89
		
	 Assumptions
	  	89
		
	 Constraints
	  	89
		
	 3. Architecture & Infrastructure Requirements
	  	90
		
	 Operational Requirements
	  	90
		
	 Scalability Requirements
	  	90
		
	 Security
	  	90
		
	 4. General Requirements
	  	91
		
	 5. HTML Requirements
	  	92
		
	 6. WML Requirements
	  	93
		
	 7. Admin Tool Requirements
	  	94
		
	 8. Reporting Requirements
	  	95
		
	 9. Testing Expectations
	  	96
		
	 10. Training Considerations
	  	97
		
	 11. Appendix A: Explanation of Requirement IDs
	  	98
		
	 12. Appendix B: Work Flow
	  	99
		
	 13. Cingular Wireless Approval
	  	100

  

 87 

 EXHIBIT H – BUSINESS REQUIREMENTS TEMPLATE 

 

	1.	Document Details 

  

			
	 Document Author
	  	
	 Location
	  	
	 Marketing Champion
	  	
		  	

 Document History 
  

					
	 Date
	  	Author	  	Revision
		  		  	
		  		  	

 Project Team 
  

					
	 Name
	  	Responsibilities	  	Contact
Information
		  		  	
		  		  	

  

 88 

 EXHIBIT H – BUSINESS REQUIREMENTS TEMPLATE 

 

	2.	Overview & Objectives 

 Include a high
level project description here. For example: The project team desires to create a new product that will do x, y and z. 
  

	 	•	 	 Scope 

 This
section should include what systems/sites are affected 
  

	 	•	 	 Terminology 

Define any acronyms and/or uncommon terms here. 
  

			
	 Term
	  	 Definition

	 BRID
	  	Identification number assigned to requirements in this document for tracking purposes. See Appendix A for a full explanation.

 

	 	•	 	 Workflow 

Describe the current business process workflow and identify any changes in this section. Illustrations should be included in Appendix B:
Workflow. 
  

	 	•	 	 Assumptions 

Assumptions or dependencies of the requirement are listed here. 

 

	 	•	 	 Constraints 

Limitations are listed here. 
  

 89 

 EXHIBIT H – BUSINESS REQUIREMENTS TEMPLATE 

 

	3.	Architecture & Infrastructure Requirements 

  

	 	•	 	 Operational Requirements 

Operational requirements should be listed here. For example, the site should maintain an uptime of 99.6%, not including scheduled down
time... 
  

	 	•	 	 Scalability Requirements 

Specify the number of concurrent users to be supported, transaction volume, etc... 

 

	 	•	 	 Security 

Does the site need to be on a secure server? If there’s an admin tool, who should have access and how should usernames/passwords be
administered? 
  

 90 

 EXHIBIT H – BUSINESS REQUIREMENTS TEMPLATE 

 

	4.	General Requirements 

  

			
	 BRID
	  	 Requirement

		  	
		  	
		  	
		  	

  

 91 

 EXHIBIT H – BUSINESS REQUIREMENTS TEMPLATE 

 

	5.	HTML Requirements 

  

			
	 BRID
	  	 Requirement

		  	
		  	
		  	

  

 92 

 EXHIBIT H – BUSINESS REQUIREMENTS TEMPLATE 

 

	6.	WML Requirements 

  

			
	 BRID
	  	 Requirement

		  	
		  	
		  	

  

 93 

 EXHIBIT H – BUSINESS REQUIREMENTS TEMPLATE 

 

	7.	Admin Tool Requirements 

  

			
	 BRID
	  	 Requirement

		  	
		  	

  

 94 

 EXHIBIT H – BUSINESS REQUIREMENTS TEMPLATE 

 

	8.	Reporting Requirements 

 Give a brief overview of
reporting requirements then list specifics in the table. If there are multiple reports, you may repeat this section for each report. 
  

			
	 BRID
	  	 Requirement

		  	
		  	
		  	

  

 95 

 EXHIBIT H – BUSINESS REQUIREMENTS TEMPLATE 

 

	9.	Testing Expectations 

 Highlight particular use
case scenarios that may be helpful to users and Quality Assurance personnel who are validating the site’s functionality in the test environment. 
  

 96 

 EXHIBIT H – BUSINESS REQUIREMENTS TEMPLATE 

 

	10.	Training Considerations 

 List groups who will
require training and specify what’s needed for each group to conduct training effectively. 
  

 97 

 EXHIBIT H – BUSINESS REQUIREMENTS TEMPLATE 

 

	11.	Appendix A: Explanation of Requirement IDs 

 IDs
are assigned to each requirement to facilitate traceability of the requirement throughout the software development lifecycle. The following subsections explain the components of Business Requirement IDs (BRIDs). 

A Cingular Wireless-assigned BRID identifies each client-provided Business Requirement. The BRID consists of three components: 

The letters BR, to identify the requirement as a Business Requirement 

A two- or three-character abbreviation identifying the feature affected by the requirement 

A three-digit, unique value assigned to the specific BR. 

Thus, a BRID of BR-ECA-010 denotes that 

It is a client-provided Business Requirement. 

The requirement is associated with the eCare feature. 

The requirement has a unique identifier of 010. 
  

 98 

 EXHIBIT H – BUSINESS REQUIREMENTS TEMPLATE 

 

	12.	Appendix B: Work Flow 

 This section should
include existing and/or proposed business process flows. This appendix should always appear in the document. If there are no business process flows to be included, please indicate with “Not Applicable”. 

 

 99 

 EXHIBIT H – BUSINESS REQUIREMENTS TEMPLATE 

 

	13.	Cingular Wireless Approval 

 This section
requires sign-off from the Marketing Champion who initiated this project. This sign-off sheet serves the following purposes: 
  

	 	•	 	 Provides a formal review and approval checkpoint for ensuring these documented requirements accomplish their intended purpose.

  

	 	•	 	 Provides a verification that these business requirements accurately define the objective, scope, and details of the new development or enhancement
request. 

 If the documentation accurately reflects the business requirement, please sign below. 

 

							
	  	 		 	  	 	 
	Marketing Champion	 		 	Date	 	

  

 100 

 EXHIBIT I – CHANGE REQUEST TEMPLATE 

 

 Cingular Change Request Submission Form 

 

							
	Date Submitted:	 		  	Date Requested By:	  	
				
	Subject of Change:	 		  		  	
		
	Affected Interfaces:	 	 ̈   HTML Portal    
 ̈  WML Portal      ̈  SMS Application    
 ̈  Admin Tool
		
	Type of Change:	 	 ̈  Problem               
                                    ̈
  Enhancement
		
	Priority:	 	 ̈  Low             
 ̈  Medium                     
 ̈  High
				
	Document Author:	 		  	Marketing Champion:	  	

 I. Objectives 
  

			
	 1
	 	
	 2
	 	
	 3
	 	
	 4
	 	

 II. Assumptions 
  

			
	 1
	 	
	 2
	 	
	 3
	 	
	 4
	 	

 III. Constraints 

			
	 1
	 	
	 2
	 	
	 3
	 	
	 4
	 	

  

 101 

 EXHIBIT I – CHANGE REQUEST TEMPLATE 

 

	IV.	Requirements 

  

	 	a.	General Requirements 

	 	1.	...... 

	 	2.	.... 

	 	3.	... 

  

	 	b.	HTML Portal Requirements 

	 	1.	.... 

	 	2.	.... 

	 	3.	... 

  

	 	c.	WML Portal Requirements 

	 	1.	.... 

	 	2.	.... 

	 	3.	.... 

  

	 	d.	SMS Application Requirements 

	 	1.	.... 

	 	2.	.... 

	 	3.	.... 

  

	 	e.	Admin Tool Requirements 

	 	1.	.... 

	 	2.	.... 

	 	3.	.... 

  

	V.	Process Flow 

 Insert
screenshots, flow charts, etc... here. 
  

 102 

 EXHIBIT J – FORM OF WORK ORDER AND PURCHASE ORDER 

 

 Work Order No.
             
 to Second Amended and Restated Wireless
Services Agreement #00014249 
 InfoSpace Mobile, Inc. (“InfoSpace”) will perform the following additional
services for Cingular Wireless LLC, a Delaware limited liability company, on behalf of itself and its Affiliates (“Company”) under the terms and conditions of that certain Second Amended and Restated Wireless Services Agreement #00014249,
dated July 22, 2005 between InfoSpace and Company (as amended, the “Agreement”). In consideration of the additional services described below, Company will pay to InfoSpace the amount(s) set forth below on or before the date(s) set
forth below. 
  

			
	 Task Description
	 	 Estimated Completion Date

	 InfoSpace will
                            
(the “Deliverable”).
	 	InfoSpace will use commercially reasonable efforts to complete the Deliverable ___________.

 

			
	 Amount
	  	 Due Date

	$                	  	Upon completion of the Deliverable, InfoSpace will send an invoice to Company for the fees payable pursuant to this Work Order. Company shall remit payment for such invoice
within thirty (30) days of the date of such invoice.

 This Work Order is made under and incorporates the terms and conditions of
the Agreement. The terms and conditions set forth in this Work Order are in addition to and not in substitution of any terms or conditions set forth in the Agreement. Except as specifically modified by this Work Order, the terms and conditions of
the Agreement remain in full force and effect. 
  

					
	InfoSpace Mobile, Inc.	 		 	Cingular Wireless LLC
			
	  	 		 	  
	Authorized Signature	 		 	Authorized Signature
			
	  	 		 	  
	Printed Name and Title	 		 	Printed Name and Title
			
	  	 		 	  
	Date	 		 	Date

  

 103 

 EXHIBIT J – FORM OF WORK ORDER AND PURCHASE ORDER 

 

 Cingular Purchase Order 

 

 

  

 104 

 EXHIBIT K – LICENSE AGREEMENT 

 

 License Agreement 

 
  

InfoSpace Mobile, Inc. 

and 
 Cingular
Wireless, LLC 
 Agreement No: 

Effective Date: 
  

 105 

 EXHIBIT K – LICENSE AGREEMENT 

 

 Table of Contents 

 

					
	 	 	Section	 	 
		
	1.	 	Definitions
		
	2.	 	License; Protection of InfoSpace Software
		
	3.	 	Delivery of InfoSpace Software; Implementation Plan
		
	4.	 	Hardware
		
	5.	 	Certain Obligations of the Parties
		
	6.	 	Payments
		
	7.	 	Warranties; Indemnification; Insurance; Limitation of Liability; Taxes
		
	8.	 	Term and Termination
		
	9.	 	Intellectual Property
		
	10.	 	General Provisions
		
		 	Exhibits
			
		 	A.	 	InfoSpace Software
			
		 	B.	 	Change Request and Acceptance Process
			
		 	C.	 	Support for InfoSpace Software
			
		 	D.	 	System Environment Specifications
			
		 	E.	 	Preliminary Implementation Plan
			
		 	F.	 	Form of Work Order
			
		 	G.	 	Commercial Terms
			
		 	H.	 	Executive Orders and Federal Regulations
			
		 	I.	 	Cingular Purchase Order

  

 106 

 EXHIBIT K – LICENSE AGREEMENT 

 

 License Agreement 

This License Agreement (“Agreement”), effective as of
            , 200_ (the “Effective Date”), is made by and between InfoSpace Mobile, Inc., a California corporation and a wholly owned subsidiary of InfoSpace, Inc., with
principal offices at 10960 Wilshire Blvd., Suite 800, Los Angeles, CA 90024 (“InfoSpace”), and Cingular Wireless, LLC, a Delaware limited liability company, on behalf of itself and its Affiliates, with principal offices at 5565 Glenridge
Connector, Atlanta, GA 30342 (“Cingular”). 
 RECITALS 

This Agreement is entered into with reference to the following facts: 

A. InfoSpace and Cingular entered into that certain Second Amended and Restated Wireless Services Agreement #00014249, effective as of
July 22, 2005 (the “Services Agreement”). 
 B. The parties are entering this Agreement pursuant to Section
         of the Services Agreement. 
 C. InfoSpace owns the software listed in
the attached Exhibit A (collectively, the “InfoSpace Software”). 
 D. Cingular wishes to license the InfoSpace
Software and to obtain support and other services from InfoSpace as set forth in this Agreement. 
 E. InfoSpace wishes to
license the InfoSpace Software and provide support and other services to Cingular as set forth in this Agreement. 
 AGREEMENT

 The parties agree as follows: 
  

	1.	Definitions. 

 As used
herein, the following terms have the following defined meanings: 
 “Active User” means a User for whom
InfoSpace reports three or more Sessions during a calendar month of the Term . 
 “Affiliate” means an entity
that has its principal place of business in the United States or Puerto Rico and that directly or indirectly, through one or more intermediaries, controls, is controlled by or is under common control with another entity. Control shall be defined as
(i) thirty percent (30%) or more ownership or beneficial interest of income and capital of such entity; (ii) ownership of at least thirty percent (30%) of the voting power or voting equity; or (iii) the exclusive or shared
ability to otherwise direct the management policies of such entity by contract or otherwise. 
 “Agreement”
means this License Agreement, including all exhibits hereto. 
  

 107 

 EXHIBIT K – LICENSE AGREEMENT 

 

 “Authorized Operator” means any individual with a need to access the
InfoSpace Software in order to perform the activities contemplated by this Agreement who is (i) an employee of Cingular, or (ii) an independent contractor or consultant of Cingular reasonably acceptable to InfoSpace, provided that such
independent contractor or consultant has agreed in writing to act in accordance with the obligations of non-disclosure and non-use imposed by this Agreement. 

“Documentation” means the documentation, training materials, specifications, notes and technical documents, and
materials sufficient to permit Cingular to use the InfoSpace Software. 
 “Error(s)” means defect(s) in the
InfoSpace Software that prevent it from performing in accordance with the Documentation. 
 “InfoSpace
Software” means the software owned by InfoSpace that is listed on Exhibit A, including any updates, new releases or Error corrections thereto. 

“Intellectual Property Rights” means any patent, copyright, rights in Trademark, trade secret rights, and other
intellectual property or proprietary rights arising under the laws of any jurisdiction. 
 “Live Date” has the
meaning set forth in Section 3.3. 
 “Object Code” means the computer software code which results from the
translation or processing of Source Code by a computer into machine executable or intermediate code, which code is not readily understandable to a human being but is appropriate for execution or interpretation by a computer. 

“Person” means any natural person, corporation, partnership, limited liability company or other entity. 

“Session” means any use of the Services by a User during any thirty minute period. 

“Services” mean the wireless services that will be hosted and made available to Users by Cingular using the InfoSpace
Software and third party software, content and applications. 
 “Source Code” means computer code in high
level, human readable language, including comments, and all tools and documentation reasonably necessary to build and/or modify such code. 

“System Environment Specifications” has the meaning set forth in Section 2.3. 

“Term” has the meaning set forth in Section 8.1. 

“Territory” means the United States and Puerto Rico. 

“Trademarks” means trademarks, service marks, trade names, proprietary logos or indicia and other source or business
identifiers. 
 “User” means any individual that is authorized by Cingular to access the Services. 

“User Data” has the meaning set forth in Section 5.8. 

 

 108 

 EXHIBIT K – LICENSE AGREEMENT 

 

 Any capitalized term used in this Agreement but not defined in this Section 1 shall
have the meaning ascribed to such term in this Agreement. 
  

	2.	License; Protection of InfoSpace Software. 

2.1 InfoSpace Software. Subject to the terms and conditions of this Agreement, InfoSpace hereby grants to Cingular for the Term, a
non-exclusive, non-transferable, fully-paid, royalty-bearing, limited license (a) to the InfoSpace Software, in Object Code form, to use solely in connection with providing the Services to Users for personal use within the Territory, and
(b) to use the accompanying Documentation in connection with Cingular’s permitted use of the InfoSpace Software. Further, Cingular will have the right to sublicense the foregoing rights to a third party hosting service provider reasonably
acceptable to InfoSpace. InfoSpace will notify Cingular of such acceptance or rejection in writing within 15 days of receiving written notification of such third party provider from Cingular. 

2.2 Protection of InfoSpace Software. Cingular will protect the InfoSpace Software using the same degree of care Cingular takes to
protect its own Confidential Information; provided, however, that, at a minimum, Cingular will: 
 (a) Not use or
permit the use of the InfoSpace Software in any manner other than to provide access to the Services to Users as provided herein; 

(b) Retain in strict confidence, and not disclose or otherwise make available, the InfoSpace Software to anyone except
Authorized Operators for use pursuant to the terms of this Agreement; 
 (c) Reproduce (and refrain from removing
or destroying) copyright and proprietary rights notices that are placed upon or within the InfoSpace Software; 

(d) Not copy or reproduce the InfoSpace Software or the Documentation; 

(e) Erase or otherwise destroy, prior to disposing of media, all portions of the InfoSpace Software contained on such
media; 
 (f) Not modify, reverse engineer, disassemble, decompile or otherwise attempt to discover the Source
Code of the InfoSpace Software, or use or refer to the InfoSpace Software for the purpose of creating software that provides functionality similar to that provided by the InfoSpace Software, or for any other purpose not expressly provided herein;

 (g) Not sublicense the InfoSpace Software or Documentation , or assign any of the rights granted to Cingular
under this Agreement except as expressly permitted under this Agreement; and 
 (h) Notify InfoSpace promptly in
writing upon learning of any unauthorized disclosure or use of the InfoSpace Software, and cooperate fully and promptly with InfoSpace to cure any unauthorized disclosure or use of the InfoSpace Software. 

 

 109 

 EXHIBIT K – LICENSE AGREEMENT 

 

 2.3 Operating Environment. Cingular will obtain, configure and maintain the
minimum requirements for the computing, network and communications environments in which the InfoSpace Software is intended to operate as specified by InfoSpace in the System Environment Specifications (“SES”), attached hereto as Exhibit
D. Among other things, the SES will set forth the hardware and third party software necessary to support the InfoSpace Software. InfoSpace may update the SES from time to time and shall promptly notify Cingular in writing of any such update.

 Upon Cingular’s request at any time during the Term and at Cingular’s expense, InfoSpace will use commercially reasonable efforts
to determine whether Cingular is in compliance with the SES, provided that InfoSpace shall provide an initial compliance certification to Cingular upon Cingular’s request at no charge and, provided further, that in the event that InfoSpace
updates the SES during the Term, InfoSpace will provide Cingular with an additional compliance certification at no charge upon notification from Cingular that Cingular has implemented such update. 

2.4 Cingular Acknowledgement. Cingular acknowledges that Cingular will be solely responsible for obtaining all necessary rights to
all third party software, hardware, content, applications and other technology required to develop and commercially deploy the Services, provided that InfoSpace will (i) use commercially reasonable efforts to transfer to Cingular its licenses
to the third party software listed in Section B(iii) of Exhibit A and (ii) use commercially reasonable efforts to sublicense to Cingular the Web Crawler software as described in Section B(iv) of Exhibit A. In the event that InfoSpace is unable
to (x) transfer to Cingular the licenses listed in Section B(iii) of Exhibit A and/or (y) sublicense to Cingular the Web Crawler software, the parties will use good faith efforts to agree to a mutually agreeable solution. 

2.5 Nonexclusivity. The parties acknowledge and agree that this Agreement is non-exclusive, and that, without limiting the
generality of the foregoing, nothing in this Agreement shall be deemed or construed to prohibit either party from participating in similar business arrangements as those described herein with any Person. 

 

	3.	Delivery of InfoSpace Software; Implementation Plan. 

3.1 Delivery of InfoSpace Software. InfoSpace will deliver and install the InfoSpace Software and deliver the Documentation to
Cingular on amutually agreed upon schedule no later than six months from the Effective Date. 
 3.2 Implementation Plan.
A preliminary Implementation Plan is attached hereto as Exhibit E (the “Preliminary Implementation Plan”). The parties will mutually develop and agree upon a more detailed Implementation Plan within thirty (30) days of the Effective
Date that will supersede the Preliminary Implementation Plan (the “Implementation Plan”). Each party will perform its designated tasks and activities described in the Implementation Plan. No act, promise or assurance of either party will
modify the terms of the Implementation Plan unless in writing and signed by both parties. The Preliminary Implementation Plan and the Implementation Plan will be Confidential Information of both parties. 

3.3 Testing; Commercial Release of Services. The Implementation Plan will include a testing procedure that will set forth a
schedule for Cingular to test the InfoSpace Software to confirm that it performs in material compliance with the Documentation. In addition, the Implementation Plan will set forth a mutually agreed timeline for the commercial deployment of the
Services that will include the date upon which the Services will be made commercially available by Cingular to Users (the “Live Date”). 
  

 110 

 EXHIBIT K – LICENSE AGREEMENT 

 

	4.	Hardware. 

 4.1
Hardware Specifications. Cingular will obtain, configure and install the hardware set forth in the SES in accordance with the specifications set forth in the SES. InfoSpace will deliver the hardware referred to in Section 4(a) of the
Services Agreement to Cingular. Cingular shall pay any fees or other costs associated with such delivery and the transfer to Cingular of any service agreements related to such hardware. 

4.2 Installation of Hardware. Upon Cingular’s request, InfoSpace will install at Cingular’s designated location(s) those
items of hardware designated in the Implementation Plan as to be installed by InfoSpace, if any. InfoSpace will invoice Cingular for the installation charges, computed at InfoSpace’s then-current standard rates, and Cingular will pay the
invoice amount(s) within forty-five (45) days of the date of invoice. Cingular will be responsible for the installation of all other hardware. 

4.3 Remote Access to Hardware. Cingular will provide remote network access to the hardware, including providing to InfoSpace the
necessary security information to access the hardware through a Virtual Private Network (VPN), or equivalent means of access for the purposes of monitoring and providing support services related to the InfoSpace Software. 

 

	5.	Certain Obligations of the Parties. 

5.1 Support. Exhibit C sets forth the parties’ respective obligations with respect to the support of the InfoSpace Software.
Cingular will allow InfoSpace personnel to implement and/or will cooperate with InfoSpace upon its request in the implementation of any bug fixes, updates or Error corrections to the InfoSpace Software, or any other support services prescribed to
InfoSpace on Exhibit C. Except as specifically stated on Exhibit C or approved in advance and in writing by InfoSpace, no Cingular or third party personnel will have access to the InfoSpace Software. To the extent any Cingular personnel has access
to the InfoSpace Software pursuant to Exhibit C, such individuals will not participate in the development of any software that provides functionality similar to that provided by the InfoSpace Software for the Term of this Agreement and for two years
thereafter. Cingular will pay InfoSpace the Support Fees set forth on Exhibit G for the support services rendered by InfoSpace hereunder. 

5.2 Technical Cooperation. Each party will provide reasonable technical cooperation to the other party in order to install and
operate the InfoSpace Software. In addition to performing the tasks assigned to Cingular in the Implementation Plan and this Agreement, Cingular agrees to provide InfoSpace with timely access to Cingular’s facilities and systems in accordance
with Section 10.1 and to assist InfoSpace to the extent reasonably necessary for InfoSpace personnel to perform InfoSpace’s obligations under the Implementation Plan and this Agreement, including but not limited to: (i) assigning and
making available for the duration of the implementation a sufficient number of Cingular personnel to perform Cingular’s obligations under the Implementation Plan and this Agreement; (ii) the timely completion of all set-up activities for
which Cingular is responsible; (iii) providing and updating all relevant information reasonably necessary for InfoSpace to perform its obligations; and (iv) establishing and maintaining the system environment described in the SES.

 5.3 Project Management. Each party will appoint a single primary point of contact for project management and
coordination. This individual will be responsible for coordinating internal teams and activities associated with the deployment of the InfoSpace Software; prioritizing issues and change requests; providing internal communication of project schedule
and status; and coordinating meetings and other joint activities between the parties. 
  

 111 

 EXHIBIT K – LICENSE AGREEMENT 

 

 5.4 Training. InfoSpace will, as requested by Cingular, provide training with
respect to the operation and use of the InfoSpace Software on a schedule and terms, and at a location to be mutually agreed upon by the parties. 

5.5 Publicity. The parties may work together to issue publicity and/or general marketing communications concerning their
relationship and other mutually agreed-upon matters, provided, however, that neither party will have any obligation to do so. Neither party will issue any such publicity or general marketing communications concerning their relationship without the
prior written consent of the other party, which shall not be unreasonably withheld or delayed. 
 5.6 Work Orders. Unless
otherwise agreed, the parties will use the process described in Exhibit B for all modifications to the InfoSpace Software. Unless otherwise agreed, the parties shall use the form attached hereto as Exhibit F (the “Work Order”) to document
any work related to modifications to the InfoSpace Software . The Work Order shall set forth the work to be performed, the associated fees for such work, and any other applicable terms and conditions. InfoSpace will perform the tasks set forth on
each Work Order and will use commercially reasonable efforts to complete such tasks according to the estimated timeline (if any) set forth on each such Work Order. Cingular will cooperate with InfoSpace and provide such assistance as InfoSpace may
reasonably request to fulfill its obligations under each such Work Order. InfoSpace’s obligation to complete the tasks specified in each such Work Order by the corresponding dates (if any) will be subject to InfoSpace’s receipt from
Cingular of all necessary technical specifications by the date set forth in each such Work Order for delivery of such materials, or if no date is set forth, by a date to be mutually agreed by the parties. 

Notwithstanding the above, no Work Order is authorized until InfoSpace is in receipt of a Cingular issued Purchase Order, the form of which is attached
hereto as Exhibit J (a “Purchase Order”). All Purchase Orders issued by Cingular hereunder shall include the corresponding Work Order as an attachment. If the terms of the Purchase Order are materially different than the terms of the Work
Order, InfoSpace may reject the Purchase Order. 
 All Work Orders and Purchase Orders will be made under and incorporate the terms and
conditions of this Agreement. The terms and conditions referenced on the form of the Purchase Order shall not apply to any Purchase Order issued in connection with this Agreement. 

5.7 Other Requirements. InfoSpace and Cingular shall fulfill their respective obligations set forth in the Exhibits. 

5.8 Use of User Data. To the extent that InfoSpace receives or has access to any personally-identifiable User data (including, but
not limited to, customer proprietary network information, profiles, User usage data and other data resulting from User use of the Services) (collectively, “User Data”), Cingular retains all rights to, and is the sole owner of, all
User Data. InfoSpace will treat all User Data as Cingular Confidential Information pursuant to Section 10.4 of this Agreement. InfoSpace will not use or disseminate or authorize the use or dissemination of any User Data for any purpose other
than in connection with the performance of InfoSpace’s obligations under this Agreement, without Cingular’s advance written permission, which may be withheld in Cingular’s sole discretion. 

 

 112 

 EXHIBIT K – LICENSE AGREEMENT 

 

	6.	Payments. 

 6.1 Fees
and Payments. Cingular shall pay to InfoSpace the License Fees and Support Fees set forth on Exhibit G in accordance with the terms and conditions of this Agreement and as set forth on Exhibit G. All payments to InfoSpace by Cingular shall be
preceded by an invoice from InfoSpace. Subject to Section 6.2, Cingular shall pay InfoSpace in accordance with the amounts stated on any invoice delivered under this Agreement within forty-five (45) days of the date of the invoice. All
payments from Cingular will state the corresponding invoice number. 
 6.2 Remuneration; Collection. Cingular shall pay
to InfoSpace the amounts as set forth on Exhibit G. Each party may accept any check or payment without prejudice to its rights to recover the balance due or to pursue any other right or remedy. No endorsement or statement on any check or payment or
letter accompanying any check or payment or elsewhere will be construed as an accord or satisfaction. Unless explicitly stated on Exhibit G, all amounts payable under this Agreement are denominated in United States dollars and each party will pay
all amounts payable under this Agreement in lawful money of the United States. In the event of a disputed amount on any invoice, the billed party shall notify the billing party of its dispute in writing within forty-five (45) days of receipt of
invoice, setting forth the reasons therefor. The billing party will respond within thirty (30) days of receipt of the billed party’s notice of dispute, at which time either (a) the billing party will agree with the claim and will
waive payment, or (b) the parties will agree to meet to resolve the dispute within a reasonable period of time. During this process, InfoSpace does NOT have the right to suspend the license of or the support for the InfoSpace Software. The
non-prevailing party will be responsible for all reasonable expenses (including attorney fees) incurred by the prevailing party in any action brought for the collection of past due amounts payable under this Agreement. 

6.3 Records and Audit. During the Term, each party shall maintain accurate records of fees received and calculations of the fees
payable to the other party pursuant to this Agreement. Either party, at its expense, and upon thirty (30) business days’ advance written notice to the other party, shall have the right to examine or audit such records in order to verify
the amounts owed to either party under this Agreement. Any such audit will be conducted, to the extent possible, during normal business hours and in a manner that does not interfere with the ordinary business operations of the audited party.

  

	7.	Warranties, Indemnification, Insurance; Limitation of Liability; Taxes. 

7.1 Warranties. 
  

	 	(a)	Each party represents and warrants to the other party that: 

1) It has the full corporate right, power and authority to enter into this Agreement and to perform the acts required of
it hereunder; its execution of this Agreement and performance of its obligations hereunder, do not and will not violate, breach, or result in a default of any contract, lease, or other agreement to which it is a party or by which it is bound, any of
which violations, breaches, or defaults could reasonably be expected to have a material adverse effect on the ability of such party to perform its obligations hereunder; 

2) Its execution of this Agreement and performance of its obligations hereunder, do not and will not conflict with the
articles of incorporation or by-laws (or other governing instruments) of such party; 
 3) When executed and
delivered, this Agreement will constitute the legal, valid and binding obligation of such party, enforceable against it in accordance with its terms; and 
  

 113 

 EXHIBIT K – LICENSE AGREEMENT 

 

 4) it will comply with all then-current applicable laws, rules, and
regulations in connection with the exercise of its rights and obligations under this Agreement (including, without limitation, any related to individual privacy). 
  

	 	(b)	InfoSpace represents and warrants to Cingular that: 

1) The InfoSpace Software does not infringe, or otherwise violate or misappropriate any copyright, patent, trade secret,
or other propriety right(s) held by any third party; 
 2) Provided that the InfoSpace Software is operated by or
on behalf of Cingular in accordance with the SES, the InfoSpace Software will perform substantially as described in the applicable Documentation; 

3) The InfoSpace Software does not include or contain any timer, clock, counter, or other routine or design which causes
the InfoSpace Software to be erased, or to become inoperable or otherwise incapable of being used in the full manner for which it was designed and licensed; 

4) To its knowledge, there are no actions, suits, or proceedings, pending or threatened, which will have a material
adverse effect on InfoSpace’s ability to fulfill its obligations under this Agreement; 
 5) Any services
provided hereunder by InfoSpace will be performed in a professional manner, and with the care, skill and diligence, and in accordance with the applicable standards, currently recognized in InfoSpace’s profession or industry; and 

6) The InfoSpace Software has year 2000 capability. Year 2000 capability means that the InfoSpace Software will:

 (i) Read, compute, store, process, display and print data involving dates, including single century and
multi-century formulas, and will not cause computational, display, storage or other errors resulting from the liability to accurately or correctly handle dates, including, but not limited to, year 2000 and February 29, 2000; and 

(ii) Include the indication of century in all date-related user interface functionality, data fields, and generated code.

 7.2 Indemnification. 
  

	 	(a)	 Cingular will defend, indemnify and hold harmless InfoSpace, and its respective directors, officers, employees and agents, from and against any and all
claims, costs, losses, damages, judgments and expenses (including reasonable attorneys’ fees) arising out of or in connection with any third-party claim alleging (i) any breach of Cingular’s representations or warranties or covenants
set forth in this Agreement or (ii) that the Services (excluding the InfoSpace Software) contain any material that is obscene, libelous or defamatory, or violates the rights of any third party, or violates any law or regulation, or infringes
any Intellectual Property Rights of any third party. InfoSpace agrees that Cingular shall have sole and exclusive control over the defense and settlement of any such third party claim. However, Cingular

  

 114 

 EXHIBIT K – LICENSE AGREEMENT 

 

	 	
shall not acquiesce to any judgment or enter into any settlement that adversely affects InfoSpace’s rights or interests without the prior written consent of InfoSpace. InfoSpace shall
promptly notify Cingular of any such claim of which it becomes aware and shall: (a) at Cingular’s expense, provide reasonable cooperation to Cingular in connection with the defense or settlement of any such claim; and (b) at
InfoSpace’s expense, be entitled to participate in the defense of any such claim. 

  

	 	(b)	InfoSpace will defend, indemnify and hold harmless Cingular, and its respective directors, officers, employees and agents, from and against any and all claims, costs,
losses, damages, judgments and expenses (including reasonable attorneys’ fees) arising out of or in connection with any third-party claim alleging (i) any breach of InfoSpace’s representations or warranties or covenants set forth in
this Agreement or (ii) that the InfoSpace Software violates the rights of any third party, or violates any law or regulation, or infringes any Intellectual Property Rights of any third party. Cingular agrees that InfoSpace shall have sole and
exclusive control over the defense and settlement of any such third party claim. However, InfoSpace shall not acquiesce to any judgment or enter into any settlement that adversely affects Cingular’s rights or interests without the prior written
consent of Cingular. Cingular shall promptly notify InfoSpace of any such claim of which it becomes aware and shall: (a) at InfoSpace’s expense, provide reasonable cooperation to InfoSpace in connection with the defense or settlement of
any such claim; and (b) at Cingular’s expense, be entitled to participate in the defense of any such claim. 

  

	 	(c)	In the event that either party, after notification of any claim for which such party is responsible, does not assume the defense of such action, such party will
reimburse the other party for all reasonable costs incurred by such other party in the defense of the claim, including, but not limited to, reasonable attorneys’ fees. 

7.3 Infringement. Without limiting InfoSpace’s other obligations under Section 7.2(b), if an injunction or order is
obtained against Cingular’s use of the InfoSpace Software (or any portion thereof) as contemplated by this Agreement or if, in InfoSpace’s opinion, the InfoSpace Software (or any portion thereof) is or is likely to become the subject of a
claim of infringement, InfoSpace will, at its expense: 
 (i) procure for Cingular the right to continued use of the
InfoSpace Software (or portion thereof) under this Agreement; or 
 (ii) after consultation with Cingular, replace or modify
the InfoSpace Software (or portion thereof) under this Agreement such that it is non-infringing and still meets the requirements of this Agreement to Cingular’s satisfaction; or 

(iii) remove such infringing InfoSpace Software and reduce any License Fees attributable to such software. 

Cingular will not be liable to InfoSpace for License Fees for the InfoSpace Software after the date that InfoSpace no longer provides the
InfoSpace Software to Cingular as a result of actual or claimed infringement. 
  

 115 

 EXHIBIT K – LICENSE AGREEMENT 

 

 7.4 Insurance. As of the Effective Date, InfoSpace maintains and will
maintain the insurance coverage set forth below: 
 Commercial General Liability: 

 

				
		
	 Combined Single Limit
	  	$	1,000,000 per occurrence
		
	 General Aggregate
	  	$	2,000,000 per policy period
		
	 Products/Completed Operations Aggregate
	  	$	2,000,000 per policy period

Internet Professional Liability: 
  

				
		
	 Data Processor’s Errors and Omissions Coverage or similar coverage
	  	$	1,000,000 per occurrence/aggregate
		
	 Information Technology Products Insurance
	  	$	1,000,000 per occurrence
		
	 Personal Injury/Advertising
	  	$	1,000,000 per occurrence

Umbrella Policy: 

$20,000,000 per occurrence 

$20,000,000 for products/completed operations aggregate 

$20,000,000 general aggregate 

Worker’s Compensation: 

$1,000,000 bodily injury by accident 

$1,000,000 bodily injury by disease 

InfoSpace has provided and shall provide upon request a Certificate of Insurance to Cingular showing coverage and limits not less than the
minimum amounts shown herein. Such insurance coverage shall have an A-VII or better rating, as rated in the A.M. Best Key Ratings Guide for Property and Casualty Insurance Companies. 

 

 116 

 EXHIBIT K – LICENSE AGREEMENT 

 

 All certificates and policies shall include a provision whereby Cingular must be given
thirty (30) days advance written notice of the insurer’s intention not to renew such policy(ies) or to cancel, replace or alter the same by reducing the required coverage. 

7.5 Limitation of Liability; Disclaimer of Warranties. 

(a) Limitation of Liability. EXCEPT FOR (A) CONFIDENTIALITY OBLIGATIONS; OR (B) THE INDEMNITY AND INFRINGEMENT INDEMNITY
OBLIGATIONS OF THIS AGREEMENT, NEITHER PARTY WILL BE LIABLE FOR CONSEQUENTIAL, INCIDENTAL, SPECIAL, OR PUNITIVE DAMAGES, OR FOR LOSS OF REVENUE OR PROFIT IN CONNECTION WITH THE PERFORMANCE OR FAILURE TO PERFORM THIS AGREEMENT, REGARDLESS OF WHETHER
SUCH LIABILITY ARISES FROM BREACH OF CONTRACT, TORT, OR ANY OTHER THEORY OF LIABILITY. EXCEPT FOR THE INFRINGEMENT INDEMNITY OBLIGATIONS OF THIS AGREEMENT, EACH PARTY’S LIABILITY UNDER THIS AGREEMENT WILL NOT EXCEED *** 

(b) Disclaimer of Warranties. EXCEPT AS SET FORTH IN THIS AGREEMENT, NEITHER PARTY MAKES, AND EACH PARTY HEREBY SPECIFICALLY
DISCLAIMS, ANY REPRESENTATIONS OR WARRANTIES, EXPRESS OR IMPLIED (INCLUDING ANY IMPLIED WARRANTY OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE AND IMPLIED WARRANTIES ARISING FROM COURSE OF DEALING OR COURSE OF PERFORMANCE), AND EACH PARTY
HEREBY SPECIFICALLY DISCLAIMS ANY CLAIM IN TORT (INCLUDING NEGLIGENCE), IN EACH CASE, REGARDING ANY SERVICES OR SOFTWARE PROVIDED UNDER THIS AGREEMENT. EXCEPT AS SET FORTH IN THIS AGREEMENT, CINGULAR ACKNOWLEDGES THAT INFOSPACE MAKES NO WARRANTY
THAT THE INFOSPACE SOFTWARE IS FREE FROM ERRORS, DEFECTS, DESIGN FLAWS OR OMISSIONS. 
 7.6 Warranty Conditions. With
respect to the InfoSpace Software, all warranties and remedies herein are conditioned upon satisfaction of each of the following conditions: 

(a) Cingular may not modify the InfoSpace Software; 

(b) The InfoSpace Software must be operated in accordance with the SES and consistent with the Documentation; 

(c) Cingular must provide InfoSpace with access to the InfoSpace Software and all related third party software and
hardware, as necessary to correct or repair any condition that causes a breach of the warranty; 
 (d) Cingular
must accept, or coordinate the installment of, any updates, bug fixes, and corrections to Errors or other solutions provided by InfoSpace to rectify any breach of warranty; 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 117 

 EXHIBIT K – LICENSE AGREEMENT 

 

 (e) Customer has not installed unauthorized software onto the hardware
operating the InfoSpace Software; and 
 (f) The InfoSpace Software has not been altered or damaged by accident,
neglect misuse or other abuse by Cingular. 
 7.7 Taxes. 

(a) InfoSpace may invoice Cingular the amount of any federal excise taxes or state or local sales taxes imposed upon the
sale of material or provision of services as separate items, if applicable, listing the taxing jurisdiction imposing the tax. Installation or labor charges must be separately stated. Cingular agrees to pay all applicable taxes to InfoSpace that are
stated on and that relate to the materials or services included on that invoice. InfoSpace agrees to remit taxes to the appropriate taxing authorities. 

(b) InfoSpace agrees to pay, and to hold Cingular harmless from and against, any penalty, interest, additional tax, or
other charge that may be levied or assessed as a result of the delay or failure of InfoSpace, for any reason, to pay any tax or file any return or information required by law, rule or regulation or by this Agreement to be paid or filed by InfoSpace.
InfoSpace agrees to pay and to hold Cingular harmless from and against any penalty or sanction assessed as a result of InfoSpace doing business with any country subject to U.S. trade restrictions. 

(c) Upon Cingular’s request, the parties shall consult with respect to the basis and rates upon which InfoSpace shall
pay any taxes for which Cingular is obligated to reimburse InfoSpace under this Agreement. If Cingular determines that in its opinion any such taxes are not payable or should be paid on a basis less than the full price or at rates less than the full
tax rate, InfoSpace shall make payment in accordance with such determinations and Cingular shall be responsible for such determinations. If collection is sought by the taxing authority for a greater amount of taxes than that so determined by
Cingular, InfoSpace shall promptly notify Cingular. InfoSpace shall cooperate with Cingular in contesting such determination, but Cingular shall be responsible and shall reimburse InfoSpace for any tax, interest, or penalty in excess of its
determination. If Cingular desires to contest such collection, Cingular shall promptly notify InfoSpace. If Cingular determines that in its opinion it has reimbursed InfoSpace for sales or use taxes in excess of the amount that Cingular is obligated
to reimburse InfoSpace, Cingular and InfoSpace shall consult to determine the appropriate method of recovery of such excess reimbursements. InfoSpace shall credit any excess reimbursements against tax reimbursements or other payments due from
Cingular if and to the extent InfoSpace can make corresponding adjustments to its payments to the relevant tax authority. At Cingular’s request, InfoSpace shall timely file any claims for refund and any other documents required to recover any
other excess reimbursements, and shall promptly remit to Cingular all such refunds (and interest) received. 

(d) If any taxing authority advises InfoSpace that it intends to audit InfoSpace with respect to any taxes for which
Cingular is obligated to reimburse InfoSpace under this Agreement, InfoSpace shall (1) promptly so notify Cingular, (2) afford Cingular an opportunity to participate on an equal basis with InfoSpace in such audit with respect to such taxes
and (3)
  

 118 

 EXHIBIT K – LICENSE AGREEMENT 

 

 
keep Cingular fully informed as to the progress of such audit. Each party shall bear its own expenses with respect to any such audit, and the responsibility for any additional tax, penalty or
interest resulting from such audit shall be determined in accordance with the applicable provisions of this Section 6.6. InfoSpace’s failure to comply with the notification requirements of this Section 6.6 shall relieve Cingular of
its responsibility to reimburse InfoSpace for taxes only if InfoSpace’s failure materially prejudiced Cingular’s ability to contest imposition or assessment of those taxes. 

(e) Cingular shall be solely responsible for all taxes imposed in connection with the sale of the Services to Users.

  

	8.	Term and Termination. 

8.1 Term. The term of this Agreement will commence on the Effective Date and, unless earlier terminated pursuant to the terms of
this Agreement, will end 
 (a) in the event that this License Agreement was entered pursuant to
Section 4(b) of the Services Agreement, on the first anniversary of the Effective Date (the “ Term”); or 

(b) in the event that this License Agreement was entered pursuant to Section 7.2 of the Services Agreement, on a date
determined by Cingular in its sole discretion (the “Term”), provided that the Term will not exceed six months. 

8.2 Termination for Breach. Either party may terminate this Agreement upon not less than thirty (30) days’ prior written
notice to the other party of any material breach hereof by such other party, provided that such other party has not cured such material breach within such thirty (30) day period. 

8.3 Return of Materials to InfoSpace. Upon expiration or termination of this Agreement, Cingular will, at InfoSpace’s
option, immediately destroy or return to InfoSpace (a) all copies of the InfoSpace Software; (b) all copies of the System Environment Specifications and any portion thereof in its possession or under its control; and (c) all InfoSpace
Confidential Information in its possession or under its control. 
 8.4 Effect of Termination. Upon expiration or
termination of this Agreement for any reason, all rights and obligations of the parties under this Agreement will be extinguished, except that: (a) all accrued payment obligations hereunder will survive such termination or expiration; and
(b) the rights and obligations of the parties under Sections 6, 7.2, 7.3, 7.5, 7.6, 7.7, 8, 9, 10.2, 10.4, 10.7, 10.8, and 10.10 through 10.15 will survive any termination or expiration of the Term. 

 

	9.	Intellectual Property. 

9.1 InfoSpace Software. As between the parties, InfoSpace reserves and retains all right, title and interest in and to the
InfoSpace Software, including all Intellectual Property Rights associated therewith. Except as specifically set forth in this Agreement, no license, or title to, or ownership of any of the InfoSpace Software is granted or otherwise transferred to
Cingular or any other Person under this Agreement. 
 9.2 Further Assurances. Each party will take, at the other
party’s expense, such action (including, without limitation, execution of affidavits or other documents) as the other party may reasonably request to effect, perfect or confirm such other party’s ownership interests and other rights as set
forth in this Section 9. 
  

 119 

 EXHIBIT K – LICENSE AGREEMENT 

 

 9.3 No Joint Development; Enhancements. The parties contemplate that there will
be no joint development of Intellectual Property under this Agreement. The parties shall not engage in joint development except as they may separately agree, in writing, in advance. Further, in no event will enhancements, adaptations, improvements,
modifications and/or derivative works (“Enhancements”) created from one party’s pre-existing Intellectual Property be considered to be jointly owned by the parties, regardless of which party creates the Enhancement, it being
understood that, subject to any licenses granted herein, such Enhancements will be the sole and exclusive property of the owner of the Intellectual Property upon which such Enhancements are based. 

9.4 Restrictions. Neither party will have any rights to any materials, content or technology provided by the other party
hereunder, except as specifically provided in this Agreement, and neither will alter, modify, copy, edit, format, translate, create derivative works of or otherwise use any materials, content or technology provided by the other party except as
explicitly provided for herein, or as approved in advance, in writing, by the other party. 
  

	10.	General Provisions. 

10.1 Access. 
  

	 	(a)	When appropriate, InfoSpace shall have reasonable access to Cingular’s premises or the premises of any third party that hosts the InfoSpace Software during normal
business hours and at such other times as may be agreed upon by the parties in order to enable InfoSpace to perform its obligations under this Agreement. InfoSpace shall coordinate such access with Cingular’s designated representative prior to
visiting such premises. InfoSpace insures Cingular that only persons employed by InfoSpace or subcontracted by InfoSpace will be allowed to enter Cingular’s premises. If Cingular requests InfoSpace or its subcontractor to discontinue furnishing
any person provided by InfoSpace or its subcontractor from performing work on Cingular’s premises, InfoSpace shall immediately comply with such request. Such person shall leave Cingular’s premises promptly and InfoSpace shall not furnish
such person again to perform work on Cingular’s premises without Cingular’s written consent. The parties agree that, where required by governmental regulations, it will submit satisfactory clearance from the U.S. Department of Defense
and/or other federal, state, or local authorities. 

  

	 	(b)	Cingular may require InfoSpace or its representatives, including employees and subcontractors, to exhibit identification credentials, which Cingular may issue in order
to gain access to Cingular’s premises for the performance of services. If, for any reason, any InfoSpace representative is no longer performing such services, InfoSpace shall promptly inform Cingular. Notification shall be followed by the
prompt delivery to Cingular of the identification credentials, if issued by Cingular, or a written statement of the reasons why said identification credentials cannot be returned. 

 

	 	(c)	 InfoSpace shall use commercially reasonable efforts to insure that its representatives, including employees and subcontractors, while on or off
Cingular’s premises, will (i) protect Cingular’s materials, buildings, and structures, (ii) not interfere with Cingular’s business operations, and (iii) perform services with care and due regard for the safety,
convenience, 

  

 120 

 EXHIBIT K – LICENSE AGREEMENT 

 

	 	
and protection of Cingular, its employees, and property and in full conformance with the policies specified in the Cingular Code of Conduct, which prohibits the possession of a weapon or an
implement which can be used as a weapon (a copy of the Cingular Code of Conduct is available upon request). 

  

	 	(d)	InfoSpace shall be responsible for insuring that all persons furnished by InfoSpace work harmoniously with all others when on Cingular’s premises.

 10.2 Dispute Resolution. 

 

	 	(a)	The parties will attempt in good faith to promptly resolve any controversy or claim arising out of or relating to this Agreement through negotiations between key
representatives of the parties, before resorting to other remedies available to them. 

  

	 	(b)	If a controversy or claim should arise which is not settled as specified in sub Section (a) above, representatives of each party who are authorized to resolve the
controversy or claim will meet at a location designated by Cingular, at least once, and will attempt to, and are empowered to, resolve the matter. Either representative may request this meeting within fourteen (14) days of such request (the
“First Meeting”). 

  

	 	(c)	Unless the parties otherwise agree, if the matter has not been resolved within twenty-one (21) days of the First Meeting, the representatives shall refer the
matter to Senior Executives, who shall have full authority to settle the dispute (herein called the “Senior Executives”). The Senior Executives will make commercially reasonable efforts to meet for negotiations within fourteen
(14) days of the end of the twenty-one (21) day period referred to above, at a site designated by Cingular. Three (3) business days prior to this scheduled meeting, the parties shall exchange memoranda stating the issue(s) in dispute
and their positions, summarizing the negotiations which have taken place, and attaching relevant documents. 

  

	 	(d)	If more than one meeting is held between the Senior Executives, the meeting shall be held in rotation at the offices of InfoSpace and Cingular.

  

	 	(e)	If the matter has not been resolved within thirty (30) days of the First Meeting of the Senior Executives (which period may be extended by mutual agreement), the
parties will attempt in good faith to resolve the controversy or claim via non-binding mediation in accordance with the American Arbitration Association’s rules for Mediation of Business Disputes. 

 

 121 

 EXHIBIT K – LICENSE AGREEMENT 

 

 10.3 Compliance with Laws. Both parties shall comply with all applicable federal,
state, county, and local rules, including without limitation, all statutes, laws, ordinances, regulations and codes (“Laws”). Conversely, nothing set forth in this Agreement, including Exhibit H, is intended to contractually obligate
either party to comply with any Laws that otherwise are not applicable to it. The parties’ obligation to comply with all applicable Laws includes the procurement of permits, certificates, approvals, inspections, and licenses, when needed, in
the performance of this Agreement. InfoSpace further agrees to comply with the Executive and Federal regulations, to the extent such regulations are applicable, as set forth in Exhibit H. The parties further agree that each is solely and exclusively
responsible for any liability for its own noncompliance with any applicable Laws and each party shall defend, indemnify, and hold the other party harmless from and against such liability. 

10.4 Confidentiality. 

Each party, which receives proprietary and/or confidential information of the other party (the “Receiving Party”), shall
retain in confidence the terms of this Agreement, and all other non-public information and know-how of the other party disclosed or acquired by the Receiving Party pursuant to or in connection with this Agreement which is either designated as
proprietary and/or confidential or by the nature of the circumstances surrounding disclosure, ought in good faith to be treated as proprietary and/or confidential (“Confidential Information”); provided that each party may disclose
Confidential Information to its immediate legal and financial consultants and to any Affiliates (and its employees) with a need to know arising as a result of this Agreement, in the ordinary course of its business. Each party agrees to use
commercially reasonable efforts to protect Confidential Information of the other party, and in any event, to take precautions at least as great as those taken to protect its own confidential information of a similar nature. The foregoing
restrictions shall not apply to any information that: (a) was known by the Receiving Party prior to disclosure thereof by the other party; (b) was in or entered the public domain through no fault of the Receiving Party; (c) is
disclosed to the Receiving Party by a third party, until such time as notified by the other party that such third party was not legally entitled to make such disclosure without violation of an obligation of confidentiality; (d) is required to
be disclosed by applicable laws or regulations (but in such event, only to the extent required to be disclosed); or (e) is independently developed by the Receiving Party without reference to any Confidential Information of the other party. Upon
request of the other party, each party shall return to the other all materials, in any medium, which contain, embody, reflect or reference all or any part of any Confidential Information of the other party. Each party acknowledges that breach of
this provision by it would result in irreparable harm to the other party, for which money damages would be an insufficient remedy, and therefore that the other party shall be entitled to seek injunctive relief to enforce the provisions of this
Section 10.4. Without limitation and subject to Section 5.8(d), Confidential Information includes User Data (Section 5.8). 

10.5 Independent Contractors 

10.5.1 InfoSpace hereby represents and warrants to Cingular that: 

 

	 	(f)	InfoSpace is engaged in an independent business and will perform all obligations under this Agreement as an independent contractor and not as the agent or employee of
Cingular; 

  

	 	(g)	InfoSpace’s personnel performing services under this Agreement shall be considered solely the employees of InfoSpace and not employees or agents of Cingular;

  

 122 

 EXHIBIT K – LICENSE AGREEMENT 

 

	 	(h)	InfoSpace has and retains the right to exercise full control of and supervision over the performance of such services and full control over the employment, direction,
assignment, compensation, and discharge of all personnel performing such services; 

  

	 	(i)	InfoSpace is solely responsible for all matters relating to compensation and benefits of all InfoSpace’s personnel who perform such services. This responsibility
includes, but is not limited to, (1) timely payment of compensation and benefits, including, but not limited to, overtime, medical, dental, and any other benefit, and (2) all matters relating to compliance with all employer obligations to
withhold employee taxes, pay employee and employer taxes, and file payroll tax returns and information returns under local, state, and federal income tax laws, unemployment compensation insurance and state disability insurance tax laws, and social
security and Medicare tax laws, and all other payroll tax laws or similar laws (all collectively hereinafter referred to as “Payroll Tax Obligations”) with respect to all InfoSpace personnel providing services; and

  

	 	(j)	InfoSpace will indemnify, defend, and hold Cingular harmless from all liabilities, costs, expenses, and claims related to InfoSpace’s failure to comply with any of
the above provisions. 

 10.5.2 Cingular and InfoSpace are independent contractors under
this Agreement, and nothing herein shall be construed to create a partnership, joint venture, franchise or agency relationship between Cingular and InfoSpace. Neither party has any authority to enter into agreements of any kind on behalf of the
other party and Cingular will not attempt to or create any license, warranty or other obligation, express or implied, on behalf of InfoSpace or any of its affiliates. 

10.6 Assignment; Merger. Neither party may assign this Agreement or any of its rights or delegate any of its duties under this
Agreement without the prior written consent of the other party, which consent shall not be unreasonably withheld or delayed. Subject to the foregoing, this Agreement will be binding upon, enforceable by, and inure to the benefit of the parties and
their respective successors and assigns. 
 10.7 Choice of Law. This Agreement shall be governed by, and construed in
accordance with, the laws of the State of New York, without reference to its choice of law rules. 
 10.8 Nonwaiver. No
waiver of any breach of any provision of this Agreement shall constitute a waiver of any prior, concurrent or subsequent breach of the same or any other provisions hereof, and no waiver shall be effective unless made in writing and signed by an
authorized representative of the waiving party. 
 10.9 Force Majeure. Neither party shall be deemed to be in default of
or to have breached any provision of this Agreement as a result of any delay, failure in performance or interruption of service, resulting directly or indirectly from acts of God, acts of civil or military authorities, civil disturbances, epidemics,
riots, wars, fires, earthquakes, transportation contingencies, strikes, or other catastrophes or occurrences, each of which are beyond such party’s reasonable control, provided such default or breach is not directly or indirectly the result, in
whole or in part, of its fault or negligence. 
  

 123 

 EXHIBIT K – LICENSE AGREEMENT 

 

 10.10 Notices. Any notice or other communication required or permitted to be
given hereunder shall be given in writing and delivered in person, mailed via confirmed facsimile or e-mail, or delivered by recognized courier service, properly addressed and stamped with the required postage, to the applicable party at its address
specified below and shall be deemed effective upon receipt. Either party may from time to time change the individual to receive notices or its address by giving the other party notice of the change in accordance with this section. 

Addresses for notices: 
  

			
	To Cingular:	  	To InfoSpace:
		
	Cingular Wireless LLC	  	InfoSpace, Inc.
	5565 Glenridge Connector	  	601
108th Ave., NE, Suite 1200
	Atlanta, GA 30342	  	Bellevue, WA 98004
	Attn: VP SCM	  	Attn: EVP, Technology and Operations
	Cc: Chief Counsel SCM	  	            Fax: (425) 201-6110
		
	 However, invoices should be mailed to:
  

Cingular Wireless LLC
 5565 Glenridge Connector

 Atlanta, GA 30342
 Attention: Data
Products***
	  	
	
	In addition, an additional copy of any notice of change of address, or of termination or any alleged breach of this Agreement, shall be thus sent to the applicable party
at the following address:

  

			
	To Cingular:	  	To InfoSpace:
		
	Cingular Wireless LLC	  	InfoSpace, Inc.
	5565 Glenridge Connector	  	601
108th Ave. NE, Suite 1200
	Atlanta, GA 30342	  	Bellevue, WA 98004
	Attention: Chief Counsel SCM	  	Attention: General Counsel
		  	            Fax: (425) 201-6110

10.11 Savings. In the event any provision of this Agreement shall for any reason is held to be invalid, illegal or
unenforceable in any respect, the remaining provisions shall remain in full force and effect. 
 10.12 Integration. This
Agreement contains the entire understanding of the parties hereto with respect to the transactions and matters contemplated hereby, supersedes all previous agreements or negotiations between InfoSpace, Inc., InfoSpace and Cingular concerning the
subject matter hereof, and cannot be amended except in writing signed by InfoSpace and Cingular. In the event of a conflict or inconsistency between any exhibit made a part of this Agreement and the remainder of this Agreement, such exhibit shall
govern. Further, in the event of a conflict or inconsistency between a Work Order and the corresponding Purchase Order, the Purchase Order will govern. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 124 

 EXHIBIT K – LICENSE AGREEMENT 

 

 10.13 Counterparts; Electronic Signature. This Agreement may be executed
in counterparts, each of which will be deemed an original, and all of which together constitute one and the same instrument. To expedite the process of entering into this Agreement, the parties acknowledge that Transmitted Copies of the Agreement
will be equivalent to original documents until such time as original documents are completely executed and delivered. “Transmitted Copies” will mean copies that are reproduced or transmitted via photocopy, facsimile or other process
of complete and accurate reproduction and transmission. 
 10.14 Conflict of Interest. InfoSpace represents and warrants
that no officer, director, employee, or agent of Cingular has been or will be employed, retained or paid a fee, or otherwise has received or will receive any personal compensation or consideration, by or from InfoSpace or any of InfoSpace’s
officers, directors, employees, or agents in connection with the obtaining, arranging, or negotiation of this Agreement or other documents entered into or executed in connection with this Agreement. 

10.15 Construction and Interpretation. 

(a) The language of this Agreement shall in all cases be construed simply, as a whole and in accordance with its fair meaning and not
strictly for or against any party. The parties agree that this Agreement has been prepared jointly and has been the subject of arm’s length and careful negotiation. Each party has been given the opportunity to independently review this
Agreement with legal counsel and other consultants, and each party has the requisite experience and sophistication to understand, interpret, and agree to the particular language of the provisions. Accordingly, in the event of an ambiguity in or
dispute regarding the interpretation of this Agreement, the drafting of the language of this Agreement shall not be attributed to either party. 

(b) Article, section, or paragraph headings contained in this Agreement are for reference purposes only and shall not affect the meaning
or interpretation of this Agreement. The use of the word “include” shall mean “includes, but is not limited to.” The singular use of words shall include the plural use and vice versa. 

(c) Cumulative Remedies: Except as specifically identified as a party’s sole remedy, any rights of cancellation, termination,
liquidated damages, or other remedies prescribed in this Agreement are cumulative and are not exclusive of any other remedies to which the injured party may be entitled. Neither party shall retain the benefit of inconsistent remedies. 

IN WITNESS WHEREOF, the Parties have duly executed and delivered this Agreement as of the Effective Date. 

 

 125 

 EXHIBIT K – LICENSE AGREEMENT 

 

					
	Cingular Wireless, LLC on behalf of itself and its Affiliates	 		 	InfoSpace Mobile, Inc.
			
	  	 		 	  
	By (signature)	 		 	By (signature)
			
	  	 		 	  
	Name	 		 	Name
			
	  	 		 	  
	Title	 		 	Title

  

 126 

 EXHIBIT K – LICENSE AGREEMENT 

 

 EXHIBIT A - LIC 

INFOSPACE SOFTWARE 
  

	A.	The Infospace Software includes the following: 

  

	 	•	 	 Content Management System (CMS) 

  

	 	•	 	 Content Publishing System (CPS) 

  

	 	•	 	 Runtime Systems 

  

	 	•	 	 Rendering Engine 

  

	 	•	 	 Device Management 

  

	 	•	 	 Alert Engine 

  

	 	•	 	 Infospace Message Gateway 

  

	 	•	 	 Parental Control 

  

	 	•	 	 User Manager 

  

	 	•	 	 MetaSearch Engine 

  

	 	•	 	 Intellifind Engine 

  

	 	•	 	 Management Console 

  

	 	•	 	 Batch Dispatcher 

  

	 	•	 	 Data Developer Program (DDP) 

  

	 	•	 	 Business Intelligence Event Management System 

  

	 	•	 	 Reporting Metadata Management Tool 

  

	 	•	 	 Mobile Data Mart Ingestion and Storage System 

 

 127 

 EXHIBIT K – LICENSE AGREEMENT 

 

	B.	Third Party Software. Subject to subsections (ii), (iii) and (iv) below, Infospace will not provide third party software to Cingular.

  

	 	(i)	InfoSpace uses the following third party software in support of the InfoSpace Software as of the Effective Date of this Agreement: 

*** 
 Upon
receipt of notice from Cingular that Cingular wishes to host the Infospace Software, Infospace will update the table set forth above. 
  

	 	(ii)	InfoSpace uses the following third party software under an open source software license and, consequently, will not transfer licenses to such software to Cingular:

 *** 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 128 

 EXHIBIT K – LICENSE AGREEMENT 

 

	 	(iii)	Upon Cingular’s request, InfoSpace will use commercially reasonable efforts to transfer its licenses to the following third party software to Cingular on a
mutually agreed schedule: 

 *** 

In the event that InfoSpace is unable to transfer the licenses listed in this Section B(iii) to Cingular, the parties will use good faith efforts to
agree to a mutually agreeable solution. 
  

	 	(iv)	InfoSpace will use commercially reasonable efforts to obtain the rights to sublicense the *** in the event that InfoSpace is unable to sublicense, the ***, the parties
will use good faith efforts to agree to a mutually agreeable solution. 

  

	C.	Destination applications are not provided in this agreement, including, but not limited to, the following: 

*** 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 129 

 EXHIBIT K – LICENSE AGREEMENT 

 

 EXHIBIT B - LIC 

A. Major Development Process: The following describes the process to be used by the parties for major enhancements to the Services
and/or the introduction of new functionality to the Services. 
  

	 	1.	Cingular submits a business requirements document, in the form attached as Exhibit H (“BRD”). 

 

	 	2.	InfoSpace reviews the BRD and returns a high-level time/cost estimate within a mutually agreed timeframe. 

 

	 	3.	Upon approval of the high level estimate, InfoSpace creates a Work Order, in the form attached as Exhibit J (“Work Order”) along with a Statement of Work that
further defines the deliverable. 

  

	 	4.	Upon approval of the Work Order, Cingular provides Infospace with a Cingular Purchase Order in the form attached as Exhibit J (“Purchase Order”)

  

	 	5.	Cingular and InfoSpace jointly review and refine the requirements. This review is to clarify any ambiguity in the original document and expose the need for any
additional information prior to the creation of the detailed specifications. 

  

	 	6.	InfoSpace creates detailed use cases and functional specifications (and returns another estimate if necessary) within mutually agreed timeframe. Use cases and
functional specifications should clearly map back to the business requirements using the requirements in the original BRD provided by Cingular. 

  

	 	7.	Cingular and InfoSpace jointly review and refine use cases and functional specifications (including test cases and test plans). 

 

	 	8.	If necessary, InfoSpace revises Work Order, and Cingular signs Work Order giving final approval for development based on the revised specifications.

  

	 	9.	InfoSpace countersigns Work Order and development begins. 

  

	 	10.	InfoSpace and Cingular jointly conduct weekly project meetings to provide project status updates and address any outstanding issues/concerns. 

 

 130 

 EXHIBIT K – LICENSE AGREEMENT 

 

 B. Change Request Process: The following describes the process to be used by the
parties for minor modifications to the Services. 
  

	 	1.	Cingular submits change request, in the form attached as Exhibit I (“Change Request”). 

 

	 	2.	InfoSpace reviews Change Request and returns a high level time/cost estimate and Work Order within mutually agreed timeframe. 

 

	 	3.	Cingular and InfoSpace jointly review the requirements. 

  

	 	4.	InfoSpace creates detailed use cases and functional specifications (and returns another estimate if necessary) within mutually agreed timeframe.*

  

	 	5.	Cingular and InfoSpace jointly review and refine use cases and functional specifications (including test cases and test plans).* 

 

	 	6.	If necessary, InfoSpace revises Work Order, and Cingular signs Work Order giving final approval for development based on the final specifications.*

  

	 	7.	Upon approval of the Work Order, Cingular provides Infospace with a Cingular Purchase Order in the form attached as Exhibit J (“Purchase Order”)

  

	 	8.	InfoSpace countersigns Work Order and development begins. 

  

	 	9.	Changes are placed in demo for Cingular’s testing/review. 

  

	 	10.	Changes are pushed to production, only upon written approval from Cingular. 

 

	*	These steps may not be required for all change requests (for example: minor copy changes or replacing ads of the same size). 

 

 131 

 EXHIBIT K – LICENSE AGREEMENT 

 

	 	C.	Acceptance Test Process 

Unless otherwise agreed by the Parties, this Exhibit D describes the process used to test and accept features for inclusion on the
Services (the “Acceptance Test Process”). The parties will cooperate in good faith to develop and implement communication mechanisms such that Cingular provides feedback to InfoSpace in a timely and efficient manner in order to
facilitate Infospace’s ability to address such feedback. Cingular shall have the right to review and test any Deliverable to determine whether it conforms to specifications or acceptance criteria in the applicable Work Order or SOW (if any) or
as otherwise agreed upon in writing by the Parties. Cingular may provide written notice of rejection (with detailed reasons for said rejection) or acceptance within the mutually agreed upon Acceptance Testing schedule from the date the
Deliverable(s) are submitted by Infospace. 
  

	 	•	 	 Following the date of delivery of a Deliverable(s) in commercial ready form (“Commercial Ready Delivery Date”), unless otherwise
mutually agreed, Infospace and Cingular, prior to the beginning of test execution, will mutually agree to the following: 

  

	 	•	 	 Schedule of test execution 

  

	 	•	 	 Scope of test execution 

  

	 	•	 	 Bug / Feature triage process 

In the event that agreed schedule must change, Infospace and Cingular will review the impact from a schedule, scope and cost perspective
and will negotiate a new agreement associated with the particular Deliverable. 
  

	 	•	 	 Following the Deliverable Acceptance Date, Infospace will commercially release the Deliverable at a mutually agreed time.

  

	 	•	 	 The “Deliverable Acceptance Date” for such Deliverable(s) will be the earlier of (a) Cingular’s commercial release of such
Deliverable(s) to its general customer base or (b) the date of Cingular’s written notification to Infospace that Infospace has completed, to Cingular’s reasonable satisfaction, changes and bug fixes identified by Cingular and Cingular
has accepted the Deliverable as being ready for commercial launch, with such acceptance not being unreasonable withheld. If applicable, Cingular shall remit payment in full to Infospace for the new Deliverable following the Deliverable Acceptance
Date and subsequent receipt of an invoice, in accordance with Section 5.1. If a Deliverable is accepted and payment remitted, Infospace agrees to use commercially reasonable efforts during the Term to remedy any known bugs/defects contained in
such Deliverable, at no additional charge to Cingular, based on a mutually agreed upon schedule. In the event Cingular rejects a Deliverable, Infospace shall resubmit such Deliverable for acceptance within thirty (30) days of the initial
rejection by Cingular. If the re-submitted Deliverable(s) do not conform to the applicable specifications or acceptance criteria, Infospace will have thirty (30) days to fix the Deliverable(s) and resubmit. If the Deliverable(s) resubmitted for
a second time does not conform to the applicable specifications or acceptance criteria, Cingular shall have the right to the following: 

  

	 	•	 	 If agreed to by Infospace, extend the period for Infospace to submit conforming Deliverable(s), or 

 

 132 

 EXHIBIT K – LICENSE AGREEMENT 

 

	 	•	 	 Terminate the applicable Work Order, in whole or in part with respect to certain feature, and require that Infospace promptly refund all payments
previously made to Infospace by Cingular for such nonconforming Deliverable(s). 

 In the event that Cingular
rejects a Deliverable and terminates a Work Order (or portion thereof), Cingular shall have the right to retain any materials that constitute Cingular Customized Work Product (see Exhibit L) related to the nonconforming Deliverable(s), provided that
Cingular pays a reasonable amount for such materials. Cingular shall promptly return to InfoSpace all materials related to such nonconforming Deliverable(s) that do not constitute Cingular Customized Work Product. 

If Cingular has not accepted (which acceptance shall not be unreasonably withheld) the Deliverable(s) within fifteen (15) business
days following the completion of all bug fixes by InfoSpace, Cingular will deliver a comprehensive list of bug fixes that Cingular requires InfoSpace to carry out prior to Cingular’s acceptance of the Deliverable(s) for commercial launch, and
representatives of the parties will meet and negotiate in good faith to define a mutually-agreed timeline and set of acceptance criteria to be used by Cingular in making such acceptance. 

 

 133 

 EXHIBIT K – LICENSE AGREEMENT 

 

 EXHIBIT C- LIC 

SUPPORT FOR INFOSPACE SOFTWARE 
  

	1.	Modifications of InfoSpace Software: 

  

	 	a.	Modifications of Infospace Software (including configuration files) may be made only by Infospace employees or Infospace designated agents. 

 

	 	b.	Modifications that require “Super Administrator” privileges may be made only by Infospace employees or Infospace designated agents. 

 

	 	c.	Modifications that may be implemented using tools installed by InfoSpace within Infospace’s Management Console and that do not require “Super
Administrator” privileges may be made by Cingular employees. 

  

	2.	Installation and Configuration of New Releases of Infospace Software: 

  

	 	a.	All major releases of Infospace Software may be installed and configured only by Infospace employees or Infospace designated agents. 

 

	 	b.	All minor releases of Infospace Software may be installed and configured only by Infospace employees or Infospace designated agents. 

 

	 	c.	All emergency releases, including “software patches” of Infospace Software may only be installed and configured by Infospace employees or Infospace designated
agents. 

  

	3.	Release and Configuration of Third Party Software: 

  

	 	a.	In the event that Cingular wants to integrate third party software with Infospace Software, and provided that such integration is permissible under the SES, Cingular
will install and configure such software to Infospace’s specifications. 

  

	 	b.	In the event that InfoSpace needs to integrate third party software with Infospace Software, InfoSpace will install and configure such software to Infospace’s
specifications. 

  

	4.	Updates of Infospace Software: Infospace may, but is not obligated to, provide updates for any of the Infospace Software. 

Nothwithstanding the above, nothing in this section will relieve InfoSpace of its obligation to provide bug fixes, corrections or updates
as required to meet its obligations under this Agreement. 
  

 134 

 EXHIBIT K – LICENSE AGREEMENT 

 

	5.	In the event that Cingular desires InfoSpace to modify the InfoSpace Software, the parties will follow the process described in Exhibit B and will use the form attached
as Exhibit F to document such modifications. 

  

	6.	Support of Infospace Software: 

  

	 	a.	Cingular responsibilities with respect to supporting Infospace Software include: 

 

	 	i.	Maintain hosting environment in compliance with SES 

  

	 	ii.	Provide updated point of contact and hours of operation for Infospace’s Carrier Care team for incident resolution. 

 

	 	iii.	Act as primary and direct contact with Users 

  

	 	iv.	Provide Tier-1 support and Triage for the hosted service, including the following: 

 

	 	•	 	 Incident identification 

  

	 	•	 	 Incident isolation 

  

	 	•	 	 Incident severity ranking in accordance with the severity definitions as set forth in Table 2. 

 

	 	•	 	 Incident notification to Infospace, including the following information: 

 

	 	a.	Cingular incident tracking number 

  

	 	b.	Incident severity 

  

	 	c.	Incident timeline: 

  

	 	i.	Time first noticed 

  

	 	ii.	Current state of incident 

  

 135 

 EXHIBIT K – LICENSE AGREEMENT 

 

	 	iii.	Frequency of recurrence 

  

	 	d.	Incident description 

  

	 	e.	Steps to reproduce the incident 

  

	 	f.	Troubleshooting steps performed prior to notifying Infospace of the incident. 

 

	 	b.	All Cingular issues related to Infospace Software will be routed through Infospace’s Carrier Care Support Center. The Infospace Carrier Care Support Services team
is an interface between Cingular’s Level 2 Support Group (Cingular’s non-customer facing group) and Infospace for support of services provided by Infospace. This arrangement provides Cingular with access to a single point of contact for
reporting incidents, receiving updates and escalation. Table 1 provides the Infospace Carrier Care hours of operation and contact information. 

  

			
	Hours of Operation	  	24 hours a day, 7 days a week and 365 days a year (7/24/365)
		
	Contact Phone Number	  	***
		
	Email Address	  	***

 Table 1, Infospace Carrier
Care Contact Information 
  

	 	c.	Issue Severity and Responsiveness: 

The Infospace Carrier Care Support Services group of Infospace will coordinate incident isolation, testing, and repair work within
Infospace. During incident isolation, troubleshooting and repair process, Infospace Carrier Care Support Services will communicate incident resolution progress with Cingular based upon the times specified in Table 2. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 136 

 EXHIBIT K – LICENSE AGREEMENT 

 

							
	 Infospace

Incident
 Level
	    	 Description
	    	Update
Method	    	 Update

Objectives

	 Severity 1
  

(Sev1)
	    	 Severity 1 problems are faults contained within the Infospace Software that render the Infospace Software inoperative.

 
 Examples of this incident level being attained include:

 
 Loss of functionality / feature to a significant number of Users

 
 A recurring anomaly impacting continuous operations of the Software
	    	Email
 or

Phone
	    	 After Cingular notifies Infospace of a Severity 1 issue:
  

***Subsequent updates ***, or upon change in status.
  

Infospace will update Cingular with the following information:
  

Incident number
  

Current status of repair
  

Estimated Time to Repair (ETR)

				
	 Severity 2
  

(Sev2)
	    	 Severity 2 problems are faults contained within the Infospace Software that render the Infospace Software partially
inoperative.
  
 Examples of this incident level being attained
include:
  
 Loss of service and/or functionality to a portion of
Users
  
 Loss of the ability to utilize some aspect of the
Software
	    	Email	    	 After Cingular notifies Infospace of a Severity 2 issue:

 
 ***

 
 •   Subsequent updates
*** or upon change in status.
  
 Infospace will update Cingular with the
following information:
  
 Incident number

 
 Current status of repair

 
 Estimated Time to Repair (ETR)

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 137 

 EXHIBIT K – LICENSE AGREEMENT 

 

							
	 Infospace

Incident
 Level
	    	 Description
	    	Update
Method	    	 Update

Objectives

	 Severity 3
  

(Sev3)
	    	 Severity 3 problems are faults contained within the Infospace Software that are generally non-service affecting conditions and either
has no material affect on operations or has very limited affect on operations.
  

Examples of this incident level being attained include:
  

Non-service impacting intermittent system faults.
  

Minor template / container bugs
	    	Email	    	 After Cingular notifies Infospace of a Severity 3 issue:
  

***
  

Infospace will update Cingular with the following information:
  

Incident number
  

Current status of repair
  

Estimated Time to Repair (ETR)

Table 2, Incident Handling Notification Timetable 

In the event that unauthorized personnel have modified Infospace Software, Infospace will be under no obligation to provide Cingular continued support of
the Software. 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 138 

 EXHIBIT K – LICENSE AGREEMENT 

 

 EXHIBIT D - LIC 

SYSTEM ENVIRONMENT SPECIFICATIONS 

Server & Network Specifications 
  

											
	 ***
	 	 	 	 	 	 	 	 	 	 

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 139 

 EXHIBIT K – LICENSE AGREEMENT 

 

 EXHIBIT E - LIC 

PRELIMINARY IMPLEMENTATION PLAN 
  

			
	***	 	

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission

  

 140 

 EXHIBIT K – LICENSE AGREEMENT 

 

 EXHIBIT F - LIC 

FORM OF WORK ORDER 

Work Order No.              

to License Agreement 

InfoSpace Mobile, Inc. (“InfoSpace”) will perform the following additional services for Cingular Wireless LLC
(“Cingular”) under the terms and conditions of that certain License Agreement dated
                                 between InfoSpace and Cingular. In consideration
of the additional services described below, Cingular will pay to InfoSpace the amount(s) set forth below on or before the date(s) set forth below. 
  

			
	 Task Description
	  	Target Date
		  	

  

			
	 Amount
	  	 Due Date

		  	

  

					
	Cingular Wireless LLC (“Cingular”)	 		 	InfoSpace Mobile, Inc. (“InfoSpace”)
			
	  	 		 	  
	By (signature)	 		 	By (signature)
			
	  	 		 	  
	Name	 		 	Name
			
	  	 		 	  
	Title	 		 	Title

  

 141 

 EXHIBIT K – LICENSE AGREEMENT 

 

 EXHIBIT G - LIC 

COMMERCIAL TERMS 
 A.
License Fees 
 Cingular will pay Infospace a license fee based on the total number of Active Users for each calendar month of the Term.
Infospace will calculate the Active User Fee as follows: 
 *** 

			
	 Number of Active Users
	  	Calculation of the Monthly Fee
	***	  	***
	***	  	***
	***	  	***
	***	  	***
	***	  	***

 In the event that the Active User Fee
exceeds *** of the Term, InfoSpace will waive the Monthly Minimum for the subsequent months of the Term; provided that, in the event the Active User Fee is less than *** of the Term, the Monthly Minimum will be reinstated. 

B. Support Fees. To the extent that InfoSpace provides support services to Cingular as described in Exhibit C of this Agreement, InfoSpace shall
charge Cingular for such services at a rate of *** 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 142 

 EXHIBIT K – LICENSE AGREEMENT 

 

 EXHIBIT H - LIC 

EXECUTIVE ORDERS AND FEDERAL REGULATIONS 

The parties to this Agreement may be subject to the provisions of certain Executive Orders, federal laws, state laws, and associated
regulations governing performance of this contract including, but not limited to: Executive Order 11246, Executive Order 11625, Executive Order 11701, and Executive Order 12138, Section 503 of the Rehabilitation Act of 1973 as amended and the
Vietnam Era Veteran’s Readjustment Assistance Act of 1974. To the extent that such Executive Orders, federal laws, state laws, and associated regulations apply to InfoSpace in the performance of work under this Agreement, and only to that
extent, InfoSpace (also referred to as “Contractor”) agrees to comply with the provisions of all such applicable Executive Orders, federal laws, state laws, and associated regulations, as now in force or as may be amended in the future,
including, but not limited to the following: 
  

	1.	EQUAL EMPLOYMENT OPPORTUNITY DUTIES AND PROVISIONS OF GOVERNMENT CONTRACTORS 

If applicable, the parties agree to comply with all regulations and contract clauses required by 41 C.F.R.§60-1.4(a), including but
not limited to, the prohibition of discrimination against any employee or applicant for employment because of race, color, religion, sex, or national origin. Further, if required under 41 C.F.R. § 60-1.4(a), Contractor will take affirmative
action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, color, religion, sex, or national origin. 

 

	2.	AGREEMENT OF NON SEGREGATED FACILITIES 

If applicable, the parties agree to comply with 41 C.F.R.§60-1.8, including the maintenance and provision for their employees of
facilities not segregated on the basis of race, color, religion, sex, or national origin at any of its establishments, and the prohibition against permitting their employees to perform their services at any location, under the control of the
employing party, where such segregated facilities are maintained. The term “facilities” as used herein means waiting rooms, work areas, restaurants and other eating areas, time clocks, rest rooms, wash rooms, locker rooms and other storage
or dressing areas, parking lots, drinking fountains, recreation or entertainment areas, transportation, and housing facilities provided for employees; provided, that separate or single-user restroom and necessary dressing or sleeping areas shall be
provided to assure privacy between the sexes. 
  

	3.	AGREEMENT OF AFFIRMATIVE ACTION PROGRAM 

Contractor agrees that, if required by 41 C.F.R.§60-1.4(b), it will maintain an Affirmative Action Plan. 

 

	4.	AGREEMENT OF FILING 

Contractor agrees that, if required by 41 C.F.R.§60-1.7(a), it will file, per current instructions, complete and accurate reports on
Standard Form 100 (EE0-1), or such other forms as may be required under 41 C.F.R.§60-1.7(a). 
  

 143 

 EXHIBIT K – LICENSE AGREEMENT 

 

	5.	AFFIRMATIVE ACTION FOR HANDICAPPED PERSONS AND DISABLED VETERANS, VETERANS OF THE VIETNAM ERA. 

In accordance with 1 C.F.R.§60-250.20, and 41 C.F.R.§60-741.20, the parties incorporate herein by this reference the applicable
regulations and contract clauses required by those provisions to be made a part of government contracts and subcontracts to the extent such provisions are applicable to this Agreement. 

 

	6.	UTILIZATION OF SMALL, SMALL DISADVANTAGED AND WOMEN-OWNED SMALL BUSINESS CONCERNS 

 

	 	a.	It is the policy of the United States that small business concerns, small business concerns owned and controlled by socially and economically disadvantaged individuals
and small business concerns owned and controlled by women shall have the maximum practicable opportunity to participate in performing contracts let by any Federal agency, including contracts and sub-contracts for systems, assemblies, components, and
related services for major systems. It is further the policy of the United States that its prime contractors establish procedures to ensure the timely payment amounts due pursuant to the terms of the subcontracts with small business concerns, small
business concerns owned and controlled by socially and economically disadvantaged individuals and small business concerns owned and controlled by women. 

  

	 	b.	To the extent required under 48 C.F.R., Ch. 1, 19.708(a), the Contractor hereby agrees to carry out this policy in the awarding of subcontracts to the fullest extent
consistent with efficient contract performance and to cooperate in any studies or surveys as may be conducted by the United States Small Business Administration or the awarding agency of the United States as may be necessary to determine the extent
of the Contractor’s compliance with this clause. 

  

	 	c.	As used in this contract, the term small business concern shall mean a small business as defined pursuant to section 3 of the Small Business Act and relevant
regulations promulgated pursuant thereto. The term small business concern owned and controlled by socially and economically disadvantaged individuals shall mean a small business concern which is at least 51 percent unconditionally owned by
one or more socially and economically disadvantaged individuals; or, in the case of any publicly owned business, at least 51 percent of the stock of which is unconditionally owned by one or more socially and economically disadvantaged individuals;
and (2) whose management and daily business operations are controlled by one or more such individuals. This term also means small business concern that is at least 51 percent unconditionally owned by an economically disadvantaged Indian tribe
or Native Hawaiian Organization, or a publicly owned business having at least 51 percent of its stock unconditionally owned by one of these entities which has its management and daily business controlled by members of an economically disadvantaged
Indian tribe or Native Hawaiian Organization, and which meets the requirements of 13 CRF part 124. The Contractor shall presume that socially and economically disadvantaged individual include Black Americans, Hispanic Americans, Native Americans,
Asian-Pacific Americans, Subcontinent Asian Americans, and other minorities, or any other individual found to be disadvantaged by the Administration pursuant to section 8(a) of the Small business Act. The Contractor shall presume that socially and
economically disadvantaged entities also include Indian Tribes and Native Hawaiian Organizations. 

  

 144 

 EXHIBIT K – LICENSE AGREEMENT 

 

	 	d.	The term “small business concern owned and controlled by women” shall mean a small business concern (i) which is at least 51 percent owned by one or more
women, or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women, and (ii) whose management and daily business operations are controlled by one or more women; and

  

	 	e.	Contractors acting in good faith may rely on written representations by their sub-contractors regarding their status as a small business concern, a small business
concern owned and controlled by socially and economically disadvantage individuals or a small business concern owned and controlled by women. 

  

	7.	SMALL, SMALL DISADVANTAGED AND WOMEN-OWNED SMALL BUSINESS SUB-CONTRACTING PLAN. 

If required under 48 CFR Ch. 1 at 52.219-9, the sub-contractor will adopt a plan similar to the plan required by 48 CFR Ch. 1 at 52.219-9.

  

 145 

 EXHIBIT K – LICENSE AGREEMENT 

 

 EXHIBIT I - LIC 

CINGULAR PURCHASE ORDER 
  

 146 

 EXHIBIT K – LICENSE AGREEMENT 

 

 

 

  

 147 

 EXHIBIT L – CINGULAR CUSTOMIZED WORK PRODUCT 

 

 InfoSpace shall develop and deliver to Cingular the items designated with an
“X” in the column below entitled “Cingular Customized Work Product” on a schedule to be mutually agreed by the parties and pursuant to the terms and conditions of this Agreement. Such items are, collectively, the “Cingular
Customized Work Product”. 
 For purposes of clarification, the items designated with an “X” in the column below
entitled “InfoSpace Technology” constitute Technology, as defined in this Agreement. InfoSpace retains all right, title and interest, including but not limited to all Intellectual Property Rights, in and to the Technology set forth below
and any other Technology utilized under or in connection with this Agreement, and no license or title to, nor ownership of, any of the Technology is granted or otherwise transferred to Cingular or any other Person except as specifically provided
under this Agreement. 
  

							
	***	  	 	  	 	  	 

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 148 

 EXHIBIT M – Security Requirements For System Or Network Access By Contractors

  

 *** 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 149 

 FIRST AMENDMENT 

TO THE SECOND AMENDED AND RESTATED 

WIRELESS SERVICES AGREEMENT #0001429 

This First Amendment (this “First Amendment”) to the Second Amended and Restated Wireless Services Agreement #0001429 of
July, 22, 2005 between InfoSpace, Inc. (“InfoSpace”) and AT&T Mobility LLC, f/k/a Cingular Wireless LLC (“AT&T Mobility”) (the “Agreement”), is made and entered into this
1st day of March, 2007 (“First Amendment Effective
Date”). Such parties are referred to herein individually as a “Party,” and collectively as the “Parties”. 

WHEREAS, InfoSpace has provided certain Services and reporting to AT&T Mobility pursuant to the Agreement; 

WHEREAS, Cingular Wireless LLC changed its name to AT&T Mobility LLC on January 8, 2007; and 

WHEREAS, InfoSpace and AT&T Mobility desire to perpetuate and continue their relationship, by doing business under the terms of the Agreement,
as amended as set forth herein. 
 NOW, THEREFORE, in consideration of the premises and the covenants hereinafter contained, the Parties
hereto agree as follows: 
  

	1.	Except as otherwise provided herein, all of the terms, covenants and conditions used, but not defined, herein shall have the meanings ascribed to them in the Agreement.
In the event of a conflict between the terms and conditions hereof, and the terms and conditions of the Agreement, the specific terms and conditions set forth in this First Amendment shall govern. 

 

	2.	All references to Cingular Wireless LLC or “Cingular” are deleted and replaced with “AT&T Mobility LLC” or “AT&T Mobility”,
respectively. 

  

	3.	Section 7.1(a) of the Agreement shall be deleted in its entirety and replaced with the following: 

 

	 	(a)	The term of this Agreement shall commence on the Effective Date and, unless earlier terminated pursuant to this Agreement, or except as provided in Section 7.1(b)
or (c), shall end on the third anniversary of the Effective Date (the “Initial Term”). After the Initial Term, this Agreement shall continue until terminated by either Party upon six months notice. 

 

	4.	Exhibit A - “Services” is hereby amended to incorporate the terms described in Exhibit A-1 Services, attached hereto and incorporated herein in accordance
with the terms of the Agreement. 

  

	5.	Exhibit C - “Commercial Terms” is hereby amended to incorporate the terms described in Exhibit C-1 Commercial Terms, attached hereto and incorporated herein
in accordance with the terms of the Agreement. 

  

	6.	The terms and conditions of the Agreement in all other respects remain unmodified and in full force and effect. 

 

 1 

 IN WITNESS WHEREOF, InfoSpace and AT&T Mobility have each caused this First Amendment to be executed by
its duly authorized representative, which may be in duplicate counterparts, each of which will be deemed to be an original instrument, as of the First Amendment Effective Date above. 

 

									
	Infospace, Inc.	 		 	AT&T Mobility LLC
					
	By:	 	/s/ Steven Elfman	 		 	By:	 	***
	Print Name:	 	Steven Elfman	 		 	Print Name:	 	***
	Title:	 	Executive Vice President	 		 	Title:	 	V.P., Supply Chain Management
		 	Mobile Division	 		 		 	

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 2 

 EXHIBIT A-1 – SERVICES 

Exhibit A – Services is amended to add two new sections (E and F), as follows: 

 

	“E.	Research and Development. AT&T Mobility will have the opportunity to meet with InfoSpace from time to time regarding InfoSpace’s Mobile Services
Platforms and/or Applications (collectively referred to as “Mobile Service”) via the following process: 

  

	 	1.	InfoSpace will schedule and host recurring monthly Mobile Service meetings. Agendas for Mobile Service meetings will be mutually agreed upon by the Parties, as follows:

  

	 	a.	InfoSpace will provide AT&T Mobility with an initial agenda no less than three weeks prior to the upcoming month’s Mobile Service Meeting.

  

	 	b.	AT&T Mobility may provide comments and items to be reasonably included in the monthly agenda, no less than two weeks prior to the upcoming month’s Mobile
Service Meeting. If AT&T Mobility does not provide comments/items within said timeframe, the agenda for that upcoming month’s Mobile Service Meeting shall be set and, as per the agenda received by InfoSpace. 

 

	 	c.	Representatives from each Party’s respective product, marketing, technology and/or engineering groups (at the Director level or higher), will attend the monthly
Mobile Service meetings. 

  

	 	2.	Mobile Service meetings will be of sufficient length and of sufficient detail to review/discuss current and future Mobile Service 

 

	 	3.	For specific roadmap features and/or capabilities (the “Mobile Features”), InfoSpace will disclose in which development phase the Mobile Features resides from
one of the following development phase categories (each a “Development Phase”): 

 Development
Phase 
  

	 	a.	Investigation Phase 

  

	 	b.	Concept Phase 

  

	 	c.	Requirements Definition Phase 

  

	 	d.	Development Phase 

  

	 	e.	Testing Phase 

  

	 	f.	Solution Phase 

  

	 	4.	As a result of the Mobile Service meetings, AT&T Mobility will be allowed to identify a subset of the Mobile Features for which InfoSpace may pursue, in its sole
discretion, for the benefit of its customers, to include AT&T Mobility, (each, an “ Mobile Feature”) for the Mobile Features that have not yet entered the Development Phase. Upon identification and agreement of the Mobile Feature,
InfoSpace may engage AT&T Mobility for its input in the “Concept Phase” and “Requirements Definition Phase” which InfoSpace may choose to incorporate at its sole discretion. 

InfoSpace will work to create joint Operations Requirements Document(s) (each, an “ORD”) for the respective Mobile Feature.
InfoSpace will develop the timeline for the Mobile Feature ORD. Once the respective Mobile Feature ORD is finalized, the Mobile Feature will progress to the Development Phase. 

 

 3 

	 	5.	Within thirty (30) days after the First Amendment Effective Date, the Parties will meet to discuss/review the Mobile Service to be pursued by InfoSpace for the
current calendar year; thereafter the Parties will meet within thirty (30) days of the start of the new calendar year and discuss/review the Mobile Service to be pursued by InfoSpace for such new calendar year. 

 

	F.	Research and Development Remedies. 

  

	1.	For every calendar month that InfoSpace does not conduct a Mobile Service meeting, A&T Mobility, *** provided that if the meeting is cancelled or rescheduled due to
AT&T Mobility’s inability to attend the Mobile Service meeting, then this provision shall be waived. 

  

	G.	SECURITIES FAIR DISCLOSURE AND NON-DISLOSURE OBLIGATIONS 

AT&T Mobility acknowledges that U.S. securities laws prohibit any person who receives material non-public information about the
discloser or any of its subsidiaries from purchasing or selling securities of the discloser or from communicating such information to any other person under circumstances in which it is reasonably foreseeable that such person is likely to purchase
or sell such securities in reliance on such information, and agrees not to purchase, sell or otherwise engage in transactions in InfoSpace’s stock based on material nonpublic information (if such information is disclosed) until such time as the
information becomes disseminated to the public either through a press release issued by InfoSpace or through a filing made by InfoSpace pursuant to the Securities Exchange Act of 1934, as amended. In addition to the foregoing and any non-disclosure
obligations in place between the Parties, AT&T Mobility agrees that, without the prior written consent of InfoSpace, it will not disclose the Mobile Service to anyone except employees with a need-to-know such information, except as required by
law or security exchange rules. The Mobile Service and associated information provided by InfoSpace as part of the process (including but not limited to Attachment 1 and the ORD) shall be considered Confidential Information and may be used only for
the purposes of fulfilling Parties obligations under this Agreement. 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 4 

 EXHIBIT C-1 – COMMERCIAL TERMS 

Exhibit C – Commercial Terms is amended as set forth herein. 

Section 3 - Active User Fee is hereby deleted and replaced in its entirety with the following. 

“3) Active User Fee 
  

	(a)	AT&T Mobility will pay InfoSpace a fee based on the total number of Active Users for each calendar month of the Term. InfoSpace will calculate the Active User Fee
as follows: *** (the “Monthly Minimum”) or the aggregate value of the following calculations: 

  

					
	 Tier
	  	 Number of Active Users
	  	 Calculation of the Monthly Fee

	1                	  	***	  	***
			
	2	  	***	  	***
			
	3	  	***	  	***
			
	4	  	***	  	***
			
	5	  	***	  	***

 *** 

 

	(b)	In the event that the Active User Fee exceeds *** of the Term, InfoSpace will waive the Monthly Minimum for the subsequent months of the Term; provided that, in the
event the Active User Fee is less than *** of the Term, the Monthly Minimum will be reinstated. Notwithstanding the foregoing, the Monthly Minimum will apply to any month of the Term during which Cingular redirects more *** to another Web Site as
described in Section 2.7 of this Agreement. 

  

	(c)	Notwithstanding Section 3(a) above, the Parties agree as follows: 

*** 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 5 

 SECOND AMENDMENT 

TO THE SECOND AMENDED AND RESTATED 

WIRELESS SERVICES AGREEMENT #00014249 

This Second Amendment (this “Second Amendment”) to the Second Amended and Restated Wireless Services Agreement #0001429 of
July, 22, 2005 between Motricity, Inc., f/k/a InfoSpace Mobile, Inc. (“Motricity” or “Supplier”) and AT&T Mobility LLC (“AT&T Mobility” or “AT&T”) (the “Agreement”), is made and entered
into this 1st day of October, 2008 (“Second Amendment
Effective Date”). Such parties are referred to herein individually as a “Party,” and collectively as the “Parties”. 

WHEREAS, InfoSpace has provided certain Services to AT&T Mobility pursuant to the Agreement; 

WHEREAS, Cingular Wireless LLC changed its name to AT&T Mobility LLC on January 8, 2007; 

WHEREAS, InfoSpace Inc. changed its name to Motricity, Inc. on December 28, 2007 and assumed all of the rights and obligations of InfoSpace
Mobile, Inc.; and 
 WHEREAS, Motricity and AT&T Mobility desire to perpetuate and continue their relationship, by doing business
under the terms of the Agreement, as amended as set forth herein. 
 NOW, THEREFORE, in consideration of the premises and the covenants
hereinafter contained, the Parties hereto agree as follows: 
  

	1.	Except as otherwise provided herein, all of the terms, covenants and conditions used, but not defined, herein shall have the meanings ascribed to them in the Agreement.
In the event of a conflict between the terms and conditions hereof, and the terms and conditions of the Agreement, the specific terms and conditions set forth in this First Amendment shall govern. 

 

	2.	All references to InfoSpace Mobile, Inc. or “InfoSpace” are deleted and replaced with “Motricity, Inc.” or “Motricity”, respectively.

  

	3.	Section 1 “Definitions” of the Agreement shall be amended to add the following definitions. 

“Email Message” means an email sent by Motricity to a User to (i) confirm changes made via the My MEdia Net or (ii) notify
such User of a change in his/her AT&T account status. 
 “Location Based Services” are services that access or use the
User’s current location information as provided by the AT&T network or directly from the mobile device. 
 “MEdia Net”
means the wireless internet made available to Users via an AT&T mobile device and refers to previous, current and future releases and excludes any legacy Services. 

“My MEdiaNet” means an AT&T website that allows Users to configure and customize their MEdia Net home page on their mobile device
via a computer. 
 “Products” means any and all equipment, software, documentation, designs, or materials, used, created or
provided by or on behalf of Motricity.  
 “Scenario Manager” means a tool that allows AT&T the ability to associate
content to one or more specific user segments and to assign Users to those segments. 
  

 1 

 “Service Defect” means a failure to provide Services and/or Products in conformance with
the requirements set forth in the respective Work Order. 
 “Work” is as defined within Exhibit I, attached hereto and
incorporated by reference herein. 
 “Work Request Form” is as set forth within Exhibit I-1, attached hereto and incorporated
by reference herein. 
 “Work Request Process” is as set forth within Exhibit I. 

 

	4.	This Agreement is amended to add the following to the end of Section 6.1 “Warranties”: 

“(g) Payment Card Industry. The terms of this Section g apply only to the extent that Motricity collects, processes, handles,
and/or maintains credit card or other personal financial data and/or related transaction status or identity information through, for, or on behalf of AT&T or its customers. The PCI Security Standards Council, LLC, is a non-AT&T entity that
owns, develops, maintains and distributes the PCI Data Security Standard, which may be updated from time-to-time (“DSS”). Throughout the term of this Agreement and at no cost to AT&T, Motricity shall comply with the then-current
requirements of DSS.” 
  

	5.	Section 6.2 “Indemnification” and Section 6.3 “Infringment” of the Agreement shall be deleted in its entirety and replaced with the
Indemnity provisions set forth within the new Section 10 “Indemnity” as set forth below. 

  

	6.	Section 6.4 “Insurance” of the Agreement shall be deleted in its entirety and replaced with the following: 

6.4 Insurance. 
  

	 	6.4	With respect to Motricity’s performance under this Agreement, and in addition to Motricity’s obligation to indemnify, Motricity shall at its sole cost and
expense: 

  

	 	6.4.1	maintain the insurance coverages and limits required by this Section and any additional insurance and/or bonds required by law: 

 

	 	6.4.1.1	at all times during the term of this Agreement and until completion of all Work associated with this Agreement, whichever is later; and 

 

	 	6.4.1.2	with respect to any coverage maintained in a “claims-made” policy, for two (2) years following the term of this Agreement or completion of all Work
associated with this Agreement, whichever is later. If a “claims-made” policy is maintained, the retroactive date must precede the commencement of Work under this Agreement; 

 

	 	6.4.2	require each subcontractor who may perform Work under this Agreement or enter upon the Work site to maintain coverages, requirements, and limits at least as broad as
those listed in this Section from the time when the subcontractor begins Work, throughout the term of the subcontractor’s Work and, with respect to any coverage maintained on a “claims-made” policy, for two (2) years thereafter;

  

	 	6.4.3	procure the required insurance from an insurance company eligible to do business in the state or states where Work will be performed and having and maintaining a
Financial Strength Rating of “A-” or better and a Financial Size Category of “VII” or better, as rated in the A.M. Best Key Rating Guide for Property and Casualty Insurance Companies, except that, in the case of Workers’
Compensation insurance, Motricity may procure insurance from the state fund of the state where Work is to be performed; and 

  

 2 

	 	6.4.4	deliver to AT&T, certificates of insurance stating the types of insurance and policy limits. Motricity shall provide or will endeavor to have the issuing insurance
company provide at least 30 days advance written notice of cancellation, non-renewal, or reduction in coverage, terms, or limits to AT&T. Motricity shall deliver such certificates: 

 

	 	6.4.4.1	prior to execution of this Agreement and prior to commencement of any Work; 

 

	 	6.4.4.2	prior to expiration of any insurance policy required in this Section; and 

  

	 	6.4.4.3	for any coverage maintained on a “claims-made” policy, for two (2) years following the term of this Agreement or completion of all Work associated with
this Agreement, whichever is later. 

  

	 	6.5	The Parties agree: 

  

	 	6.5.1	the failure of AT&T to demand such certificate of insurance or failure of AT&T to identify a deficiency will not be construed as a waiver of Motricity’s
obligation to maintain the insurance required under this Agreement; 

  

	 	6.5.2	that the insurance required under this Agreement does not represent that coverage and limits will necessarily be adequate to protect Motricity, nor be deemed as a
limitation on Motricity’s liability to AT&T in this Agreement; 

  

	 	6.5.3	Motricity may meet the required insurance coverages and limits with any combination of primary and Umbrella/Excess liability insurance; and 

 

	 	6.5.4	Motricity is responsible for any deductible or self-insured retention. 

  

	 	6.6	The insurance coverage required by this Section includes: 

  

	 	6.6.1	Workers’ Compensation insurance with benefits afforded under the laws of any state in which the Work is to be performed and Employers Liability
insurance with limits of at least: 

 $500,000 for Bodily Injury – each accident 

$500,000 for Bodily Injury by disease – policy limits 

$500,000 for Bodily Injury by disease – each employee 

To the fullest extent allowable by Law, the policy must include a waiver of subrogation in favor of AT&T, its Affiliates, and their
directors, officers and employees. 
 In states where Workers’ Compensation insurance is a monopolistic state-run
system, Motricity shall add Stop Gap Employers Liability with limits not less than $500,000 each accident or disease. 
  

	 	6.6.2	Commercial General Liability insurance written on Insurance Services Office (ISO) Form CG 00 01 12 04 or a substitute form providing equivalent coverage,
covering liability arising from premises, operations, personal injury, products/completed operations, and liability assumed under an insured contract (including the tort liability of another assumed in a business contract) with limits of at least:

 $2,000,000 General Aggregate limit 

$1,000,000 each occurrence limit for all bodily injury or property damage incurred in any one (1) occurrence 

$1,000,000 each occurrence limit for Personal Injury and Advertising Injury 

$2,000,000 Products/Completed Operations Aggregate limit 
  

 3 

 $1,000,000 each occurrence limit for Products/Completed Operations 

$1,000,000 Damage to Premises Rented to You (Fire Legal Liability) 

The Commercial General Liability insurance policy must: 

 

	 	6.6.2.1	include AT&T, its Affiliates, and their directors, officers, and employees as Additional Insureds. Motricity shall provide a copy of the Additional Insured
endorsement to AT&T. The Additional Insured endorsement may either be specific to AT&T or may be “blanket” or “automatic” addressing any person or entity as required by contract. A copy of the Additional Insured
endorsement must be provided within 60 days of execution of this Agreement and within 60 days of each Commercial General Liability policy renewal; 

  

	 	6.6.2.2	include a waiver of subrogation in favor of AT&T, its Affiliates, and their directors, officers and employees; and 

 

	 	6.6.2.3	be primary and non-contributory with respect to any insurance or self-insurance that is maintained by AT&T. 

 

	 	6.6.3	Business Automobile Liability insurance with limits of at least One Million Dollars ($1,000,000) for each accident for bodily injury and property damage,
extending to all owned, hired, and non-owned vehicles. 

  

	 	6.6.4	Umbrella/Excess Liability insurance with limits of at least One Million Dollars ($1,000,000) for each occurrence with terms and conditions at least as broad as
the underlying Commercial General Liability, Business Auto Liability, and Employers Liability policies. Umbrella/Excess Liability limits will be primary and non-contributory with respect to any insurance or self-insurance that is maintained by
AT&T Mobility. 

  

	 	6.6.5	Professional Liability (Errors & Omissions) insurance with limits of at least One Million Dollars ($1,000,000) for each claim or wrongful act.

  

	7.	Section 7.1(a) of the Agreement shall be deleted in its entirety and replaced with the following: 

 

	 	(a)	The term of this Agreement shall commence on the Effective Date and, unless earlier terminated pursuant to this Agreement, or except as provided in Section 7.1(b)
or (c), shall end on January 22, 2010 (the “Initial Term”). After the Initial Term, this Agreement shall continue until terminated by either Party upon six months notice. 

 

	8.	Section 7.3 “Termination for Convenience” shall be deleted in its entirety and replaced with the following: 

7.3 Termination for Convenience. 
  

	 	7.3.1	Agreement. Effective January 22, 2010, AT&T Mobility may terminate this Agreement without cause upon six (6) months advance written notice.

  

	 	7.3.2	Legacy Services. Effective as of January 1, 2007 AT&T Mobility may terminate the Legacy Services, in whole or in part, upon providing Motricity with
sixty (60) days advance written notice and following the effective date of such termination, AT&T Mobility shall not be obligated to pay the applicable Legacy Services Fees as set forth in Section B of Exhibit C – Commercial Terms.

  

 4 

	9.	Section 7.4 “Effect of Termination” shall be deleted in its entirety and replaced with the following: 

7.4 Obligations upon Termination or Transition of Service. 
  

	 	7.4.1	*** by AT&T Mobility, Motricity shall reasonably cooperate with AT&T in the orderly and expeditious wind down and/or transition of its Services (in whole or in
part) to a different service provider (“Transfer”). For purposes of clarity, such advance, written notice will not extend the six-month notice period for termination for convenience. 

 

	 	7.4.2 	The Transfer will be performed by the parties in accordance with a mutually agreed upon Statement of Work and will include such items as transition responsibilities
(such as migration of subscribers, subscriber data, premium digital content, transaction data, and/or Merchant integrations), key resources, Transfer timelines, related fees (such as operating expenses to sustain Services from the Cut-Over Date,
defined below, until the Transfer is complete “Sustainment Fees”), etc. 

 With respect to Sustainment
Fees the Parties acknowledge and agree to the following: 
 A) Sustainment Fees may include: 

 

	 	1)	*** 

 B) Sustainment Fees
will not include: 
  

	 	1)	*** 

  

	 	2)	*** 

  

	 	3)	*** 

  

	 	4)	*** 

  

	 	7.4.3. 	Motricity will provide all services, information and documentation as may be reasonably needed by AT&T in connection with the Transfer. 

 

	 	7.4.4. 	Unless otherwise specified by AT&T, the minimum period of time to affect such a Transfer will be nine months and may be extended upon mutual agreement of the
parties (“Wind Down Period”). Both parties are required to make a good faith effort to fulfill the requirements of the Transfer as quickly as possible within the Wind Down Period. 

 

	 	7.4.5. 	Services provided by Motricity during the Wind Down Period shall be provided to AT&T at the rates provided for in the Agreement and all terms and conditions of this
Agreement shall remain in full force and effect. 

  

	10.	This Agreement is hereby amended to add a new Section 7.5 “Effect of Termination” as follows: 

7.5 Effect of Termination. Upon termination of this Agreement for any reason or expiration of the Term, all rights and obligations of the parties
under this Agreement shall be extinguished, except that: (a) all accrued payment obligations hereunder shall survive such termination or expiration; and (b) the rights and obligations of the parties which by their nature would continue
beyond termination or expiration, including Sections 3.11(d), 5, 6.2, 6.3, 6.5, 6.6, 7, 8, and 9.2 through 9.15, shall survive such termination or expiration. Upon termination or expiration of this Agreement, Motricity will promptly return all User
Data upon receipt of notification from AT&T. 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 5 

	11.	This Agreement is hereby amended to delete Section 9.3 “Compliance with Laws” in its entirety and replace with the following: 

“9.3 Compliance with Laws. 

Motricity shall comply with all applicable federal, state, county, and local rules, and all foreign laws for any similar jurisdiction
applicable to the performance of Motricity’s obligations, including without limitation, all statutes, laws, ordinance, regulations and codes (“Laws”) with respect to its performance under this Agreement, including but not limited
to (a) the procurement of permits, certificates, approvals, inspections, and licenses (b) filing all required reports relating to such performance (including, without limitation, tax returns), (c) paying all filing fees and federal,
state and local taxes applicable to Motricity’ business as the same shall become due, and (d) paying all amounts required under local, state and federal workers’ compensation acts, disability benefit acts, unemployment insurance acts
and other employee benefit acts when due. AT&T will not be responsible for any of the foregoing payments, obligations, taxes or benefits. 

In furtherance of AT&T’s commitment to workplace diversity as an equal opportunity employer, Motricity will, while performing any
Services and at all other times while on AT&T property or conducting any AT&T related business, comply with all applicable local, state and federal laws, including specifically all laws prohibiting harassment or discrimination of any kind in
the workplace. 
  

	12.	This Agreement is hereby amended to delete Section 9.4 in its entirety and replace with the following: 

“Section 9.4 – Intentionally Omitted”. 

For purposes of clarity, Section 18 of this Second Amendment incorporates the new confidentiality provisions that will apply to this
Agreement. 
  

	13.	This Agreement is hereby amended to delete Section 9.10 “Notices” in its entirety and replace with the following: 

“9.10 Notices. 

All notices or demands given hereunder or required by law will be given in writing, will refer to this Agreement and will be effective i)
upon the date of personal delivery if delivered by hand; ii) upon the date of confirmed receipt if delivered by facsimile ii) or upon the date of receipt by recognized overnight courier; or iv) three (3) days after deposit in the United States
mail (registered or certified mail, postage prepaid, return receipt requested). Any party may change such address by giving the other party written notice of such change, referencing the change as a modification to this paragraph of this Agreement.

  

 6 

			
	AT&T MOBILITY:	  	AT&T Mobility LLC.
		  	Attn: ***
		  	 16221 NE 72d Way Redmond, WA 98052

Phone: ***

		  	Fax: ***
		
	WITH A COPY TO:	  	AT&T Mobility LLC.
		  	Attn: Legal Department – SCM Counsel
		  	1025 Lenox Park Boulevard – Ste D594
		  	Atlanta, GA 30319
		  	 Phone: (404) 986-1672
 Fax:
(404) 986-9003

		
	CONTRACTOR:	  	Motricity Inc.
		  	Motricity Inc.
		  	 601
108th Ave. NE– Suite 800

Phone: 425.957.6200
 Fax:
425-957-6201

		
	WITH A COPY TO:	  	Motricity, Inc.
		  	Attn: General Counsel
		  	601
108th Ave. NE– Suite 800
		  	Bellevue, WA 98004
		  	 Phone: 425.957.6200
 Fax:
425.957.6201

  

	14.	This Agreement is hereby amended to add a new Section 9.16 “Background Checks” as follows: 

“9.16 Background Checks 
  

	 	9.16.1	Motricity, with respect to the following requirements in this Section (collectively, “Background Checks”) and subject to any laws, rules or regulations which
may limit and/or prohibit any Motricity action otherwise required by this section, (i) shall make all reasonable efforts, including checking the background, verifying the personal information and conducting a Drug Screen to verify to AT&T
Mobility that no Motricity employee, or subcontractor and no employee or agent of Motricity or its subcontractor (“Supplier Person”) which Motricity has assigned to support the provisioning of the Services (“Supplier Person Services
Assignment”) and who Motricity proposes to physically visit AT&T Mobility or its customers’ premises, (“Access”) at any time during such Supplier Person Services 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 7 

	 	 	Assignment, (a) has presented a positive Drug Screen, (b) has been arraigned or convicted of (i) any felony, or (ii) any misdemeanor involving
violence, theft or computer crimes, fraud or financial crimes, or crimes involving unlawful possession or use of a dangerous weapon, and (ii) Motricity shall not knowingly permit any such Supplier Person presenting a positive Drug
Screen, so arraigned or convicted, or so identified to perform any Service that permits such Access during the term of the Agreement. 

  

	 	9.16.2	Motricity shall not knowingly permit any Supplier Person who has (i) falsified any of his or her Identification Credentials, or (ii) failed to disclose any
material information in the hiring process relevant to the performance of any Service. Motricity shall not knowingly permit any Supplier Person who has falsified such Identification Credentials or failed to disclose such information to perform any
Service that permits Access. 

  

	 	9.16.3	The following definitions apply to this Section: 

  

	 	•	 	 “Identification Credentials” includes, with respect to each Supplier Person, his or her Social Security number, driver’s license,
educational credentials, employment history, home address, and citizenship indicia. 

  

	 	•	 	 “Drug Screen” means the testing for the use of illicit drugs (including opiates, cocaine, cannabinoids, amphetamines, and
phencyclidine (PCP)) of any Supplier Person who (i) has unsupervised (or badged) physical Access to AT&T Mobility or its customer’s premises, or (ii) has regular or recurring supervised physical Access to AT&T Mobility or its
customer’s premises for more than thirty (30) days in the aggregate annually. 

  

	 	9.16.4	The failure of Motricity to comply with the requirements of this Section, and/or if any Supplier Person who fails such Background Check or who has falsified
Identification Credentials does perform any Service that permits such Access, shall each be considered a material breach of this Agreement. Notwithstanding any of the foregoing, exceptions for individual Supplier Person(s) may be granted by AT&T
Mobility on a case-by-case basis. 

  

	 	9.16.5	If a Supplier Person is providing any Service (e.g., software development) that permits or requires Access to AT&T Mobility’s software source or origin code or
encrypted software, Motricity shall conduct an initial, and thereafter an annual, search, in each case to verify that such Supplier Person is not identified on the Denied Person List or Specially Designated Nationals List by the U.S. Dept. of
Commerce-Bureau of Industry & Security. 

  

	15.	The Agreement is hereby amended to add a new Section 9.17 “Third Party Administrator” as follows: 

“9.17 Third Party Administrator 
  

	 	9.17.1	Motricity acknowledges that a third party administrator will perform certain administrative functions for AT&T Mobility in relation to this Agreement. Such
administrative functions may include: (i) collecting and verifying certificates of insurance; (ii) providing financial analysis; (iii) verifying certifications under the Section entitled “Utilization of Minority, Women, and
Disabled Veteran Owned Business Enterprises”; and (iv) collecting and verifying Motricity profile information. 

  

 8 

	 	9.17.2	Motricity shall cooperate with such third party administrator in its performance of such administrative functions and shall provide such data as from time to time the
third party administrator may request. Further, notwithstanding any other provision of this Agreement, Motricity agrees that AT&T Mobility may provide confidential Information regarding Motricity to such third party administrator (subject to
such third-party administrator’s obligations of non-use and non-disclosure with respect to such confidential Information). *** 

  

	16.	The Agreement is hereby amended to add a new Section 9.18 “Utilization of Minority, Women and Disabled Veteran Owned Business Enterprises” as follows:

 “9.18 Utilization of Minority, Women, and Disabled Veteran Owned Business Enterprises. 

 

	 	9.18.1	It is the policy of AT&T Mobility that minority, women, and disabled veteran owned business enterprises (“MWDVBEs”) shall have the maximum practicable
opportunity to participate in the performance of contracts. 

  

	 	9.18.2	Motricity shall make good faith efforts to carry out this policy in the award of subcontracts, distribution agreements, resale agreements, and other opportunities for
MWDVBE participation. In furtherance of those efforts, and not as a limitation, Motricity shall submit annual participation plans, at the time of contract execution and each subsequent year by January 7, establishing Motricity’s goals for
the year for participation by minority owned business enterprises (“MBE”), women owned business enterprises (“WBE”) and disabled veteran business enterprises (“DVBE”), with “participation” expressed as a
percentage of aggregate estimated annual purchases by AT&T Mobility and its Affiliates for the coming year under this Agreement. Motricity shall include specific and detailed plans for achieving its goals in each participation plan as set forth
in this Agreement. Motricity’s participation goals for the first year (that is, the calendar year that ends on December 31 next following the effective date of this Agreement) are: *** Motricity’s initial supplier participation plan
for the first year is attached to and incorporated into this Agreement as Appendix G. 

  

	 	9.18.3	By the fourteenth day following the close of each calendar quarter , Motricity shall report actual results of its efforts to meet its goals during the preceding
calendar quarter to AT&T Mobility’s Prime Supplier Program Manager, using the form attached to this Agreement as Appendix H. Motricity shall submit separate reports for AT&T Mobility and each Affiliate making purchases under this
Agreement. When reporting its results, Motricity shall count only expenditures with MWDVBEs that are certified as MBE, WBE, or DVBE firms by certifying agencies that are recognized by AT&T Mobility, as listed on Appendix G. In particular,
when reporting results for expenditures by Affiliates identified as “California Affiliates” in Appendix G, Motricity shall count only expenditures (i) with MBE and WBE firms certified by the California Public Utilities Commission
Supplier Clearinghouse (“CPUCC”) and (ii) with DVBE firms certified by the Office of Small Business and DVBE Certification (“OSDBC”) of the California Department of General Services. 

 

	 	9.18.4	Motricity shall inform prospective MBE, WBE, and DVBE subcontractors of their opportunities to apply for certification from the agencies listed in Appendix G. In
particular, Motricity shall inform MBE and WBE firms certified by agencies other than the CPUCC and the DVBE firms certified by agencies other than the OSDBC of the procedures for applying for an additional certification from the OSDBC and the
CPUCC. 

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 9 

	 	9.18.5	The extent to which suppliers (a) set challenging goals in their annual participation plans and (b) succeed in exceeding the goals that they have set are
factors that AT&T Mobility may consider favorably when deciding to extend or renew expiring agreements, to apportion orders among competing suppliers under existing agreements, and to award new business in competitive bidding.

  

	 	9.18.6	Motricity’s obligations under this Section are not a limitation of any obligations that Motricity may have under other provisions of this Agreement, including the
Section entitled “Executive Orders and Federal Regulations”. 

  

	17.	The Agreement is hereby amended to add a new Section 10 “Indemnity” as follows: 

10. Indemnity. 
  

	 	10.1	Intellectual Property Rights Indemnity 

  

	 	10.1.1	Generally. 

  

	 	10.1.1.1	Motricity will defend, indemnify and hold harmless AT&T and its affiliates, subsidiaries, contractors, distributors, and customers (hereinafter referred to
individually as “Indemnified Party” and collectively as “Indemnified Parties”) from and against any and all losses, costs, damages, expenses, liabilities, demands, claims, actions, and lawsuits (including without limitation
consultant, attorney and other legal fees) that may be asserted against, incurred or suffered by, imposed on, or awarded against any Indemnified Party arising out of or in connection with, in whole or in part, any allegation, threat, demand or
claim (or settlement thereof) that the Products or Services, related documentation, or related services, in whole or in part, whether alone or in combination with other products and services of the Indemnified Party, infringe, dilute, tarnish, or
misappropriate any copyright, industrial design, mask work, moral right, patent, right of publicity, trademark, trade secret, utility model, or other proprietary or intellectual property right or license of any person or entity (an
“Infringement Claim”). AT&T will indemnify (subject to the limitations in Section 6.5 (“Limitation of Liability; Disclaimer”) Motricity against copyright or trademark infringement actions filed against Motricity by a
third party unaffiliated with Motricity, to the extent based on Motricity’s permitted use of materials produced and provided by AT&T; provided that Motricity give AT&T prompt written notice of such action and provide AT&T with all
reasonably requested assistance. 

  

	 	10.1.1.2	In the event that a third party brings an Infringement Claim against Motricity, its affiliates, or any Indemnified Party, Motricity shall: (i) pay all consultant,
attorney and other legal fees and expenses incurred by or on behalf of an Indemnified Party in that party’s efforts to assess if the use, sale, offer to sell, or importation of any Products or Services infringes any pending or issued patent or
utility model (“Infringement Assessment”) or related to the avoidance of such infringement; and (ii) fully assist the Indemnified Party in the Infringement Assessment by promptly providing to the Indemnified Party, upon that
party’s request, all relevant information or material in Motricity’s possession or control that has been used by Motricity itself in making such assessment, including but not limited to, any in-house or outside counsel opinions, subject to
appropriate measures and agreements between the parties to preserve any privilege that may apply to such information. If following an Infringement Assessment, AT&T believes in its sole discretion that there is a possibility that AT&T’
use, sale, offers to sell, or importation of any Products or Services or related documentation infringes a third-party’s issued patent or utility model, AT&T may, upon notice to Motricity, terminate this Agreement. Such termination or
failure to so terminate shall not be an exclusive remedy and shall not in any manner limit AT&T’s other remedies or Motricity’s indemnification obligations under this Agreement. 

 

 10 

	 	10.1.1.3	MOTRICITY AGREES THAT, NOTWITHSTANDING ANY OTHER PROVISION IN THIS AGREEMENT TO THE CONTRARY (AND WHETHER OR NOT SUCH A PROVISION CONTAINS LANGUAGE THAT REPRESENTS
ITSELF AS TRUMPING OTHER PROVISIONS CONTRARY TO IT), WHETHER EXPRESS OR IMPLIED: (I) MOTRICITY SHALL INDEMNIFY AND HOLD HARMLESS THE INDEMNIFIED PARTIES FROM AND AGAINST ANY AND ALL ACTUAL, ENHANCED, EXEMPLARY, INCIDENTAL, PUNITIVE, SPECIAL,
TREBLE AND CONSEQUENTIAL DAMAGES ASSERTED AGAINST, INCURRED OR SUFFERED BY, IMPOSED ON, OR AWARDED AGAINST ANY INDEMNIFIED PARTY IN CONNECTION WITH MOTRICITY’S INDEMNIFICATION OBLIGATIONS SET FORTH IN THIS SECTION 10.1; AND (II) NONE
OF THE LIMITATIONS OF LIABILITY CONTAINED ANYWHERE IN 

 THIS AGREEMENT WILL APPLY TO MOTRICITY’S OBLIGATIONS
UNDER THIS SECTION 10.1. 
  

	 	10.1.2	Procedure. Notwithstanding any provision to the contrary contained in this Agreement or elsewhere (including without limitation other indemnification provisions
in this Agreement), AT&T and Motricity agree that with respect to Intellectual Property Indemnification under this Section 10.1, AT&T shall have the option to either (i) control the defense of any claims or actions regarding
Motricity’s obligations under this Section 10.1, or (ii) allow Motricity to control such defense, and, if AT&T chooses to allow Motricity to control the defense, then: 

 

	 	10.1.2.1	AT&T may, at its option, participate and appear with Motricity in the defense, settlement and compromise of any claims or actions regarding Motricity’s
obligations under this Section 10.1; 

  

	 	10.1.2.2	In the event of any claims or actions regarding Motricity’s obligations under this Section 10.1, if, in the absence of an injunction or other judicial action,
Motricity desires to settle or compromise such claims or actions and such settlement or compromise would in any manner involve any action or forbearance by any Indemnified Party, prior to agreeing to any such settlement or compromise Motricity shall
obtain the written consent of AT&T, which may be withheld in AT&T’s reasonable discretion. In the event AT&T reasonably withholds such consent, Motricity shall not be relieved of its indemnification obligations under this
Section 10.1; and 

  

	 	10.1.2.3	If any claims or actions regarding Motricity’s obligations under this Section 10.1 are to be settled or satisfied solely by the payment of money by Motricity,
Motricity may control such settlement or satisfaction. 

  

	 	10.1.3	Upon Injunction. 

  

	 	10.1.3.1	 Without in any manner limiting the foregoing indemnification obligations, in the event of an injunction or other judicial action preventing or
restricting an Indemnified Party’s use or enjoyment of the Products or Services, in whole or in part, Motricity shall at Motricity’s sole expense and at Motricity’s sole option and direction, either: (i) procure for the
Indemnified Party the right to continue using the infringing Products or Services; (ii) replace such Products or Services with a non-infringing product or service without loss of any functionality and that is, and in full compliance with all of
the representations and warranties set forth in this Agreement, and all specifications and requirements applicable to the Product or Service, which substitute product Motricity

  

 11 

	 	
shall fully deploy, and Motricity shall fully compensate the Indemnified Party for all costs, expenses and fines associated with such replacement; or (iii) modify such Deliverable(s)(without
loss of any functionality and such that the Product or Service is fully compliant with all of the representations and warranties set forth in this Agreement and all specifications and requirements applicable to the Product or Service), to make them
non-infringing and after which modification, the Products or Services will be in full compliance with all of the representations and warranties set forth in this Agreement, which modified product Motricity shall fully deploy, and Motricity shall
fully compensate the Indemnified Party for all costs, expenses, and fines associated with such modification and deployment. 

  

	 	10.1.3.2	Intentionally omitted. 

  

	 	10.1.3.3	If in AT&T’s reasonable discretion, AT&T believes compliance with any injunction or other judicial action which prevents or restricts an Indemnified
Party’s use or enjoyment of the Products or Services, in whole or in part, would require an Indemnified 

Party to take any action or forebear from any action such that: (i) any services provided or performed by AT&T might be
interrupted or diminished to any material degree; or (ii) any customers’ use of services provided by AT&T might be interrupted or diminished to any degree, then at AT&T’s direction, Motricity shall use its best efforts to stay
or appeal such an injunction or judicial action. 
  

	 	10.1.3.4	Without excusing Motricity from any of Motricity’s other obligations set forth in this Section 10, if in Motricity’s reasonable discretion neither option
(i), (ii), nor (iii) in Section 10.1.3.1 can be attained, or, in fact, none of the options are in fact obtained, AT&T in its sole discretion may choose to return to Motricity the Products or Services in AT&T’s
possession, and Motricity will refund to AT&T all amounts paid for the development of the Products or Services and services provided under this Agreement, reduced on a straight-line amortization basis over five (5) years.

  

	 	10.1.3.5	The remedies in this Section 10.1.3 are nonexclusive and shall not in any manner limit AT&T’s other remedies or Motricity’s indemnification
obligations under this Agreement. 

  

	 	10.2	General Indemnity 

  

	 	10.2.1	Motricity agrees to indemnify, defend, and hold AT&T harmless from any and all liabilities, causes of action, lawsuits, penalties, claims or demands (including the
costs, expenses and reasonable attorneys’ fees on account thereof) that may be made by: 

  

	 	10.2.1.1	Anyone for injuries of any kind, including but not limited to personal injury, death, property damage and theft, arising out of or resulting from Motricity’s
negligent or willful acts or omissions or those of persons furnished by Motricity, its agents or its subcontractors or resulting from use of Motricity’s Products and/or Services furnished hereunder or resulting from Motricity’s failure to
perform its obligations hereunder; or 

  

	 	10.2.1.2	Any of either Motricity’s, its agents’ or its subcontractors’ employees or former employees for which the Motricity’s, its agents’ or its
subcontractors’ liability to such employee or former employee would otherwise be subject to payments under the state Workers’ Compensation laws or an Employer’s Liability policy, premises liability principles or any other law or form
of legal duty or obligation; and 

  

 12 

	 	10.2.1.3	Either Motricity’s, its agents’ or its subcontractors’ employees or former employees, including applicants at AT&T’s job site, for any and all
claims arising out of the employment relationship with respect to performing under this Agreement. This includes, but is not limited to, employment discrimination charges and actions arising under Title VII of The Civil Rights Act of 1964, as
amended; The Equal Pay Act; The Age Discrimination Act, as amended; The Rehabilitation Act; The Americans with Disabilities Act; The Fair Labor Standards Act; The National Labor Relations Act; and any other applicable law. 

 

	 	10.2.1.4	Anyone in connection with a breach of the representations and warranties set forth in Section 9.3 “Compliance with Laws” and Exhibit E “Executive
Orders and Federal Regulations”. 

  

	 	10.2.2	Intentionally omitted. 

  

	 	10.3	The foregoing indemnity shall be in addition to any other indemnity obligations of Motricity set forth in this Agreement. 

 

	 	10.4	Notice by AT&T. In connection with any claim for indemnity under this Section 10, AT&T agrees to notify Motricity promptly of any written claims or
demands against an Indemnified Party for which Motricity is responsible under this Section 10. AT&T’s failure to notify Motricity on a timely basis will excuse Motricity from its obligations only to the specific extent Motricity has
been prejudiced thereby. 

  

	 	10.5	Notice by Motricity. Motricity agrees to notify AT&T promptly of any written claims or demands against an Indemnified Party for which Motricity is
responsible under this Section 10. 

  

	18.	The Agreement is hereby amended to add a new Section 11 “Confidential Information” as follows: 

11. Confidential Information. 
  

	 	11.1	AT&T Information 

  

	 	11.1.1	Any Information furnished to Motricity in connection with this Agreement, including Information provided under a separate Nondisclosure Agreement in connection with
discussions regarding the Service, prior to executing this Agreement, shall remain AT&T’s property. Unless such Information was previously known to Motricity free of any obligation to keep it confidential, or has been or is subsequently
made public by AT&T or a third party, without violating a confidentiality obligation, Information shall be kept confidential by Motricity, shall be used only in performing under this Agreement, and may not be used for other purposes except as
may be agreed upon between Motricity and AT&T in writing. Motricity is granted no rights or license to such Information, except as otherwise expressly set forth herein. All copies of such Information, whether in written, graphic or other
tangible form, shall be returned to AT&T upon the earlier of (i) AT&T’s request or (ii) upon Termination, Cancellation, or expiration of this Agreement. 

 

	 	11.1.2	Motricity understands and agrees that any and all field trial results prepared by AT&T are and shall remain the property of AT&T and are hereby considered
AT&T’s proprietary Information. Therefore, it shall be AT&T’s option, in its sole discretion, to furnish Motricity copies of such documents or to discuss such documents with Motricity. Motricity’s use of field trial reports
furnished by AT&T shall be governed by the Publicity section in addition to the provisions contained in this section, Information. 

  

 13 

	 	11.1.3	Motricity will not be required to protect AT&T’s Information from disclosure to the extent: (a) the Information has been publicly disclosed by AT&T;
(b) AT&T in writing authorizes Motricity to disclose without restriction; (c) Motricity already lawfully knows the Information at the time it is disclosed by AT&T without an obligation to keep it confidential; (d) Motricity
lawfully obtains the Information from any source other than AT&T, provided that such source lawfully disclosed such information; or (e) Motricity independently develops such Information without use of or reference to AT&T’s
Information. 

  

	 	11.2	AT&T Data 

  

	 	11.2.1	Motricity acknowledges that AT&T has all ownership rights to the data provided by AT&T to Motricity under the terms of this Agreement (“AT&T
Data”) and Motricity agrees to treat all AT&T Data relating to AT&T’s business as confidential and to be used only for the purpose of providing Services to AT&T under this Agreement. At AT&T’s request, Motricity shall
remove from the AT&T account any personnel of Motricity that AT&T believes is not treating AT&T Data in a manner consistent with terms of this Section 11.2.1. The terms of this Section 11.2.1 provision shall not apply to such
AT&T Data as are publicly available, independently developed by Motricity or rightfully obtained from third parties. 

  

	 	11.2.2	Customer Information. To the extent that Motricity receives or has access to any personally-identifiable AT&T customer or AT&T personnel data (including,
but not limited to, name, address, telephone number, credit card information, social security number, Customer Proprietary Network Information, profiles, customer usage data and/or other data resulting from Customer’s use of the services)
(collectively, “Customer Information”), AT&T retains all rights to, and is the sole owner of, all Customer Information. Motricity will treat all Customer Information pursuant to Exhibit M to this Agreement. Motricity will not use or
disseminate or authorize the use or dissemination of any Customer Information for any purpose other than in connection with the performance of Motricity’s obligations under this Agreement, without AT&T’s advance written permission,
which may be withheld in AT&T’s sole discretion. 

  

	 	11.2.3	Protection and Security of Customer Information. Motricity will not use or disclose, or permit others to use or disclose, any Customer Information except as
necessary for Motricity to fulfill its obligations under this Agreement, or otherwise in accordance with AT&T’s written instructions. Motricity will take all reasonable precautions to protect Customer Information against unauthorized
disclosure or alteration, theft, or other misuse including without limitation, maintaining and enforcing safety and security procedures and policies with respect to access, handling and maintenance of Customer Information reasonably designed to
(i) insure the integrity and security of Customer Information; (ii) protect against any reasonably foreseeable threats or hazards to the integrity or security of Customer Information; and (iii) protect against unauthorized access to
or use of Customer Information that could result in substantial harm or inconvenience to AT&T or its customers. Further, the Parties will cooperate with each other on an ongoing basis to evaluate security standards and will evaluate in good
faith recommendations made by the other to protect the security and integrity of Customer Information. 

  

	 	11.2.4	Privacy. In addition to any other protections afforded under this Agreement, Customer Information will be subject to AT&T’s privacy policy, as may
be changed by AT&T in its discretion from time to time (found at http://www.wireless.att.com/privacy/) and the current version of which is attached hereto as Exhibit N. 

 

 14 

	 	11.3	Motricity Information 

  

	 	11.3.1	Any Information furnished to AT&T in connection with this Agreement, including Information provided under a separate Nondisclosure Agreement in connection with
discussions regarding the Service, prior to executing this Agreement, shall remain Motricity’s property. Unless such Information was previously known to AT&T free of any obligation to keep it confidential, or has been or is subsequently
made public by Motricity or a third party, without violating a confidentiality obligation, Information shall be kept confidential by AT&T, shall be used only in performing under this Agreement, and may not be used for other purposes except as
may be agreed upon between Motricity and AT&T in writing. AT&T is granted no rights or license to such Information. All copies of such Information, in written, graphic or other tangible form, shall be returned to Motricity upon the earlier
of (i) Motricity’s request or (ii) upon Termination, Cancellation, or expiration of this Agreement. 

  

	 	11.3.2	AT&T will not be required to protect Motricity Information from disclosure to the extent: (a) the Information has been publicly disclosed by Motricity;
(b) Motricity in writing authorizes AT&T to disclose without restriction; (c) AT&T already lawfully knows the Information at the time it is disclosed by Motricity without an obligation to keep it confidential; (d) AT&T
lawfully obtains the Information from any source other than Motricity, provided that such source lawfully disclosed such information; or (e) AT&T independently develops such Information without use of or reference to Motricity’s
Information. 

  

	 	11.4	Discloser of Confidential Information 

  

	 	11.4.1	In the event a party receives a court order, or is otherwise required by law to disclose any confidential Information, such party will (a) notify the other
immediately upon receipt of such court order or other document requiring disclosure, such that the party whose confidential Information may be disclosed has time to object and/or move for a protective order, and (b) file any information
disclosed in response to such order under seal and/or request that the court seal such confidential Information. Such notice must include, without limitation, identification of the Information to be so disclosed and a copy of the order. The
disclosing party will disclose only such Information as is legally required and will use its best reasonable efforts to obtain confidential treatment for any Information that is so disclosed. Except as may ultimately be required by such court order
or law, each party’s obligations with regard to such confidential Information, as set forth above, will remain in full force and effect. 

  

	19.	Professional Services; Custom Development and Service Requests. As of the Second Amendment Effective Date, all professional services, custom development and
service requests for new Services will be handled under the Service Agreement Numbered 20081030.028.C executed between AT&T and Motricity within an effective date of October 1, 2008 (“Services Agreement’). Based on the foregoing,
the following provisions of this Agreement do not apply to any Services performed on or after the Second Amendment Effective Date. 

  

	 	i)	Section 1 “Cingular Customized Work Product” 

  

	 	ii)	Section 3.9 Future Services; Work Orders 

  

	 	iii)	ii) Section 8.3 Cingular Customized Work Product 

  

 15 

	 	iv)	Section 8.7 No Joint development; Enhancements 

  

	 	v)	Exhibit D – Section A “Major Development Process 

  

	 	vi)	Exhibit L – Cingular Customized Work Product 

  

	20.	New Services; Work Orders. New or future Services will be incorporated into this Agreement via Amendment. Work Orders may be issued under this Agreement solely
for (i) the purchase and/or installation of hardware and software that Motricity purchases on behalf of AT&T in providing Services to AT&T (ii) ad-hoc maintenance and (iii) the creation of reports. No Work Order is authorized
until Motricity is in receipt of an AT&T issued Purchase Order. All Purchase Orders issued by AT&T hereunder shall include the corresponding Work Order as an attachment, using the Work Order Form in Exhibit J. If the terms of the Purchase
Order are materially different than the terms of the Work Order, Motricity may reject the Purchase Order. 

 All
Work Orders and Purchase Orders shall be made under and incorporate the terms and conditions of this Agreement. The terms and conditions referenced on the form of the Purchase Order shall not apply to any Purchase Order issued in connection with the
Agreement. 
  

	21.	Work Requests. Work Requests will be issued by either Party where updates/modifications to Services are requested and will require the execution of Work Orders.

  

	22.	Location Based Services. With respect to the Location Based Services, Motricity understand and agrees that it may not share location information with any
third-party party vendor unless (a) AT&T approves of such disclosure and (b) Motricity complies with any location based rules communicated in advance and in writing by AT&T. 

 

	23.	Exhibit A - “Services” is hereby amended to incorporate the terms described in Exhibit A-2 Services, attached hereto and incorporated herein.

  

	24.	Exhibit C - “Commercial Terms” is hereby amended to incorporate the terms described in Exhibit C-2 Commercial Terms, attached hereto and incorporated herein.

  

	25.	Exhibit D - “Change Request and Acceptance Test Process” is hereby amended to delete in its entirety Section B “Change Request Process” and Section
C “Acceptance Test Process”. 

  

	26.	Exhibit G - “Service Level Agreement” is hereby nullified as of June 1, 2008 and the terms and conditions of Exhibit G-1 “Service Level Agreement
– WAP based Services”, attached hereto and incorporated by reference, will apply as of June 1, 2008. , attached hereto and incorporated herein. 

 

	27.	Exhibit G - 2 “Service Level Agreement for WEB Services” attached hereto is incorporated into the Agreement as of October 15, 2007. The parties agree and
acknowledge that SLA penalties for the first WEB-based Service did not take effect until February 1, 2008. 

  

	28.	Exhibit H “Business Requirements Template” is hereby deleted in its entirety. 

 

	29.	Exhibit I “Change Request Template” is hereby deleted in its entirety and replaced with Exhibit I “Work Request and Acceptance Process” and Exhibit
I-1 “Work Request Form”, both of which are attached hereto and incorporated herein. 

  

	30.	Exhibit J “Form of Work Order and Purchase Order” is hereby deleted in its entirety and replaced with Exhibit J “Work Order Form”.

  

 16 

	31.	Exhibit M - “Security Requirements for System or Network Access by Motricitys” is hereby deleted in its entirety and replaced with Exhibit M-1–Security
Requirements, a copy of which is attached hereto and incorporated herein. 

  

	32.	The Agreement is hereby amended to add Exhibit N – “AT&T Privacy Policy” attached hereto and incorporated herein. 

 

	33.	The terms and conditions of the Agreement in all other respects remain unmodified and in full force and effect. 

IN WITNESS WHEREOF, Motricity and AT&T Mobility have each caused this Second Amendment to be executed by its duly authorized representative, which
may be in duplicate counterparts, each of which will be deemed to be an original instrument, as of the Second Amendment Effective Date above. 
  

									
	Motricity, Inc.	 		 	AT&T Mobility LLC
					
	By:	 	/s/ Ryan Wuerch	 		 	By:	 	***
	Print Name:	 	Ryan Wuerch	 		 	Print Name:	 	***
	Title:	 	CEO	 		 	Title:	 	V.P., Supply Chain Management
		 	12/19/08	 		 		 	12/19/08

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 17 

 EXHIBIT A-2 – SERVICES 

TABLE OF CONTENTS 

Exhibit A – Services - is amended to insert the table of contents to reflect updates to Section headers and numbering sequence: 

 

	A.	Services 

  

	B.	Description of Services. 

  

	 	1.	Platform and Services; Legacy Services 

  

	 	(a)	Platform and Services 

  

	 	(b)	Legacy Services 

  

	 	2.	Content 

  

	 	(a)	AT&T Mobility Sourced Content 

  

	 	(i)	Integration with AT&T Mobility Sourced Content 

  

	 	(b)	Motricity Sourced Content 

  

	 	(i)	Modification of Motricity Sourced Content 

  

	 	3.	PIM/Email Service 

  

	 	4.	Personalized/Customized Content 

  

	C.	Motricity Supported Handsets 

  

	 	1.	Current Devices 

  

	 	2.	New Devices 

  

	 	3.	AT&T Mobility Network; Gateways 

  

	 	4.	Additional Support 

  

	D.	Reporting 

  

	 	(a)	Usage Reports 

  

	 	(b)	Legacy Usage Reports 

  

	 	(c)	Legacy Alert Reports 

  

	 	(d)	General Services Report 

  

	E.	Research and Development 

 The Parties
agree and acknowledge that the previously identified 
  

	F.	Research and Development Remedies 

  

	G.	Securities and Fair Disclosure 

Exhibit A – Services, Section E Research and Development (as set forth in the First Amendment) is amended to replace “monthly”
Mobile Service meetings with “quarterly” Mobile Service meetings. 
  

 18 

 EXHIBIT C-2 – COMMERCIAL TERMS 

Exhibit C – Commercial Terms is amended as set forth herein. 

 

	1.	Section 2 – SMS Fee is hereby renamed to Messaging Fee. 

The following text is deleted from Section 2: 

“Cingular will pay Infospace a fee based on the total number of SMS Messages for each calendar month of the Term.” 

and replaced in its entirety with: 

“AT&T Mobility will pay Motricity a fee based on the total number of SMS Messages and Email Messages for each calendar month of
the Term.” 
  

	2.	Section B –Fees for Legacy Services is hereby deleted and replaced in its entirety with the following. 

 

	“B	Fees for Legacy Services. At the end of each calendar month during the Term, AT&T Mobility shall pay to Motricity a fee *** (the “Legacy Services
Fee”). Motricity will invoice AT&T Mobility for the Legacy Services Fee following each applicable month of the Term and AT&T Mobility shall pay Motricity, subject to Section 5.2 of the Agreement. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 19 

	3.	Section C – is hereby added to Exhibit C as follows: 

  

	“C.	Operations and Management Fees. The following fees represent additional and (incremental) costs to Motricity in hosting and operating new and/or enhanced
Services (to include third-party integrations) provided on behalf of AT&T that are not covered by the Portal User Fee and may include such items as hardware sustainment, software licensing, IT support, incremental power, and facility impacts
(space, power, people). 

 Motricity shall invoice and AT&T Mobility will pay the operations and management fees as set forth
below (collectively “Operations and Management Fees”), pursuant to Section 5.2 of the Agreement. 
  

	 	1)	*** 

  

	 	3)	*** 

  

	 	4)	*** 

  

	 	5)	*** 

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 20 

 EXHIBIT G-1 – SERVICE LEVEL AGREEMENT – WAP BASED SERVICES 

 

	1.	General Information 

  

	1.1.	Purpose 

 The purpose of this document is
to identify the levels of service that will be maintained by Motricity and to provide this information to operations personnel of both parties responsible for the monitoring and/or support of the Services. 

 

	1.2.	Scope 

 This Service Level Agreement (SLA)
describes the basic level of service that will be provided by Motricity in its support of the delivery of the Services to AT&T for WAP based applications (“WAP Services”). For purposes of clarity reference to Services in this SLA means
the WAP Services. This agreement describes the requirements for the following: 
  

	 	a)	support and maintenance of all Motricity and third-party hardware and software for the Services 

 

	 	b)	7x24x365 support and response requirements for support calls; 

  

	 	c)	fixes, patches, and minor enhancements; 

  

	 	d)	new software releases that contain fixes to defects in production feature functionality; and 

 

	 	e)	on-site resources to support acceptance testing, trouble shooting, and system upgrades. 

This SLA also defines requirements for response (including email, telephone, remote, and on-site) and resolution timeframes related to Severity 1,
Severity 2, and Severity 3 incidents, as well as non-performance financial penalties which will be owed to AT&T for failures to meet certain obligations defined herein. 

This document also defines expectations relating to: 
  

	 	•	 	 Motricity and AT&T Responsibilities with respect to the Services 

 

	 	•	 	 Service Performance Objectives 

  

	 	•	 	 Incident Management 

  

	 	•	 	 Incident Reporting Process 

  

	 	•	 	 Operational Reports 

  

	 	•	 	 Change Control Management 

This document should be used as a reference for AT&T’s Network Operations and its contracted affiliates and Motricity in support of the
Services. It provides the framework for surveillance, isolation, analysis, and resolution of problems related to the Services. 
 As a means to
ensure the highest level of accuracy and efficiency for both AT&T and Motricity, this SLA supersedes all existing Service Level Agreements relating to the Services. 

For a complete list of the Services that are subject to this SLA, see the SLA Monitoring Requirements (Appendix D) below. 

 

	1.3.	Out of Scope 

 The following items are
deemed to be outside the scope of this SLA; however, both parties will make a good faith effort to establish the following independently from this SLA. 

*** 
  

 21 

	1.4.	Definitions 

 For purposes of this SLA the
following definitions shall apply: 
 “Service Area” refers to the specific Service components for which
financial consequences for non-performance apply under this SLA. 
 “MEdia Net Home Page” is a Service Area that
refers to the default landing page for MEdia Net. 
 “MEdia Net Category Applications” is a Service Area that
refers to the MEdia Net Service applications provided to AT&T by Motricity and/or hosted by Motricity for AT&T since November 17, 2005 

“MEdia Net Active Links” or “Active Links” is a Service Area that means links which can be added to a
User’s MEdia Net Home Page, can be either dynamic or static. Dynamic Active Links are those which contain both category links and dynamic content which is updated periodically throughout the day. Static Activel Links are bookmarks which do not
contain feed-driven dynamic content (also referred to as “Bubbles.”) 
  

	2.	Responsibilities and Services 

 This
Section 2 describes Motricity’s support responsibilities with respect to the Services, and the corresponding responsibilities of AT&T. 
  

	2.1.	Motricity Responsibilities 

 Motricity
will provide day-to-day service operations, maintenance and administration in support of the Services that are within Motricity’s Span of Control, as described below. 

Span of Control is defined as those areas of functionality that are under the direct control of Motricity. This includes functionality that is provided
by external vendors or suppliers with whom Motricity has a contractual relationship, including feeds from providers of Motricity Sourced Content. 

It is the intention of Motricity to expeditiously remedy incidents that have been identified either internally by Motricity or AT&T. Corrective
action by Motricity assumes that the incident is within its Span of Control and AT&T has provided all relevant information, if available, to Motricity. See the section entitled Mandatory Information for Incident Reporting for required reporting
information. 
 Motricity will pursue the resolution of an incident with outside vendors provided Motricity has a contractual arrangement with
the vendor. During the resolution period, Motricity will issue updates to AT&T pursuant to the severity of the incident, as described later in this document. 

Any third party content provider contracted directly by AT&T is not a party to this agreement. Any loss of content from such providers is outside of
Motricity’s Span of Control. 
  

	2.2.	Motricity Carrier Care 

 The Motricity
Carrier Care Support Services team is an interface between AT&T’s Level 2 Support Group (AT&T’s non-customer facing group) and Motricity for support of services provided by Motricity. This arrangement provides AT&T with access
to a single point of contact for reporting incidents, receiving updates and escalation. Table 1 provides the Motricity Carrier Care hours of operation and contact information. A complete list of all contacts is also shown in Appendix A. These
contacts are to be contacted per the escalation procedures outlined in Section 3. 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 22 

			
	Hours of Operation	  	24 hours a day, 7 days a week and 365 days a year (7/24/365)
		
	Contact Phone Number	  	***
		
	Email Address	  	***

 Table 1, Motricity Carrier Care Contact Information

  

	2.2.1.	Motricity Support Services 

 The following list
identifies services that are offered by Motricity Support Services to AT&T: 
  

	 	•	 	 Telephone and email support for incident resolution 

  

	 	•	 	 Advisory Bulletins 

  

	 	•	 	 Notification of planned maintenance activities 

  

	 	•	 	 Post Mortem Reports for Severity 1 (SEV1) and recurring incidents classified as Severity 2 (Sev2) including a Root Cause Analysis (RCA) upon request.
*** 

  

	2.3.	AT&T Responsibilities 

 AT&T will
provide support for Incident Management as detailed in Section 4. 
  

	3.	Service Performance Objectives 

  

	3.1	Service Availability 

 Service
Availability (SA) is defined as the amount of time the service is up excluding planned Maintenance and AT&T caused outages, computed as: 

*** 
 The above calculations allow a weighting
for partial outages and degraded service, such that only the fraction of Users denied service contributes to negative Service Availability. 
  

	3.1.1	Service Availability Target  

 Motricity
shall provide an overall system service availability *** for all Services listed in the SLA Monitoring Requirements (Appendix D) below, measured at no less than the frequency shown in Appendix D and reported at monthly intervals as described in
Section 6.2 below. This measurement excludes downtimes caused by AT&T and service interruptions due to planned maintenance approved in advance by AT&T. 
  

	3.2	Service Latency 

 User requests for
Services shall be fulfilled in accordance with Table 2 below for each calendar month. This includes delivery of all bytes of the response (content plus protocol overhead) that Motricity controls (i.e. service requests and subsequent requests for
which the browser’s URL target is hosted by Motricity). Motricity will achieve the latency targets set forth in Table 2 below on the schedule set forth in Table 2. The parties agree to review such latency targets from time to time during the
Term and to assess whether to adjust the latency. Unless otherwise mutually agreed, these are the targets for penalties as set forth in Section 8.3. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 23 

									
	 Period
	 	 Percentile 1
	 	 Latency Target 1
	 	 Percentile 2
	 	 Latency Target 2

	 ***
	 	***	 	***	 	***	 	***
					
	 ***
	 	***	 	***	 	***	 	***
					
	 ***
	 	***	 	***	 	***	 	***

 Table 2, Latency Target Ramp

 These requirements are specific to the portion of end to end Latency incurred within the Motricity’s Span of Control and will be
measured from the secure network nearest the Motricity border router. The design of latency monitoring infrastructure will ensure appropriate components of the request and response are adequately measured. The implementation of latency monitoring
infrastructure will include the deployment of a separate and specific server(s) for the purpose of monitoring and fault management. The latency introduced by the GPRS network, the WAP Gateway and other elements of the AT&T Network are excluded
from the latency measurements described above. 
  

	3.3	Legacy Components Supporting Media Net 

The following Legacy Services will not be held to the Service Availability as noted above but will meet the legacy Service Availability *** a monthly
basis as set forth below: 
 *** 

Service Availability (SA) is defined as the amount of time the service is up excluding planned Maintenance and AT&T caused outages, computed as:

 *** 
 The above calculations allow
a weighting for partial outages and degraded service, such that only the fraction of Users denied service contributes to negative Service Availability. 

*** 
  

	3.4	*** 

  

	3.5	Third-Party Content Providers 

 Motricity
will be responsible for the performance, service availability and service latency of all providers of Motricity Sourced Content with whom Motricity has a contract. Where such content provider contracts exist, Motricity will perform appropriate
alarming, monitoring and fault management to ensure that performance of these providers fully supports the service objectives defined in this SLA. Motricity will also identify those content providers to AT&T and provide notification of changes
to such contractual relationships no less than 30 days in advance of such changes becoming effective. 
 Expectations for processing of third
party content feeds as set forth in Appendix D are as follows: For streaming content (sports scores and stock quotes) and breaking news, all received content must be processed and published a maximum *** For all other content feeds that are updated
at least once a day, content must be processed and published within a maximum of *** For all other content feeds (those updated less frequently than once per day), the content must be processed and published as soon as possible, and will at all
times display content for the current day. 
 Motricity will also provide monthly reporting of service interruptions, availability measures and
other data for contracted providers of Motricity Sourced Content in accordance with Section 6. 
 In addition, Motricity will be
responsible for all degradations and service impacting issues affecting the Services that are caused by providers of Motricity Sourced Content from a Motricity SLA performance perspective. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 24 

	4.	Incident Management 

  

	4.1.	Incident Resolution Responsibilities 

Incident resolution requires teamwork between Motricity and AT&T. A key element in this teamwork approach is AT&T’s understanding of the User
service(s) offered by Motricity. 
 All AT&T identified incidents concerning failures of the Services that cannot be solved by AT&T
representatives will be reported to Motricity Carrier Care Support Services, pursuant to the Reporting Process procedures outlined below. AT&T will assign a Severity Level per Table 4. If Motricity disagrees with the Severity assignment, both
parties will negotiate in good faith after the resolution of the incident but all restoration will proceed based upon AT&T’s initial Severity assignment. 

Any reported incident that is caused by a failure that is outside Motricity’s Span of Control and not directly related to its delivery of a
subscriber service will be returned to AT&T with an appropriate explanation. Should Motricity determine that an incident being worked by Motricity Carrier Care Support Services is within AT&T’s control, the incident will be closed and
returned to AT&T for proper resolution. 
  

	4.1.1.	AT&T Contact Information 

 In order
for Motricity Carrier Care to effectively resolve Incidents, it is necessary for Motricity to have an accurate list of AT&T’s designated key personnel. This information will be exchanged between the two parties and updated as changes
warrant. Appendix A shows the type of contact information required, showing the current contacts at the Effective Date. This data will be maintained and updated by the two parties outside of this SLA document. 

 

							
	 AT&T
	 	 Hours of Operation
	 	 Role
	 	 Phone/Email

	NSD National Operations Center	 	24 x 7 x 365	 	Incident Management and Emergency Maintenance	 	***
				
	MMS External Partner Ops	 	 8:00 am – 5:00 pm PT

Monday – Friday
	 	Incident Root Cause Analysis, Change Management, Performance Reports and Tier 2 Support	 	***
				
	Change Management	 	 8:00 am – 5:00 pm PT

Monday – Friday
	 	Maintenance Notification – all maintenance	 	***

 Table 3, AT&T Contact Information 

 

	4.1.2.	AT&T Responsibilities 

 The following
section identifies the responsibilities of AT&T as it relates to this Service Level Agreement. 
  

	4.1.2.1.	General Responsibilities 

  

	 	•	 	 Acts as the primary and direct contact with the User. 

 

	 	•	 	 Answers simple questions and resolves minor issues such as resetting passwords or creating new User accounts. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 25 

	4.1.2.2.	Incident Responsibilities 

  

	 	•	 	 Creates a trouble ticket that clearly states the problem after gathering all pertinent information about the incident including name, User number,
password and any other additional information that is important to resolution of the incident. 

  

	 	•	 	 Records any subsequent conversation with the User relative to the incident in the same trouble ticket. 

 

	 	•	 	 “Owns” the resolution of an incident by coordinating its resolution within AT&T operational and technical environment and with Motricity
or its designees. 

  

	 	•	 	 Resolves the incident with the User or determines that the capability is outside the scope of current functionality. 

 

	 	•	 	 Explains the resolution of the incident to a technical peer or is capable of targeting the root technical problem for resolution.

  

	 	•	 	 Describes the incident in technical terms to an engineer or developer who is responsible for resolution of the incident. 

 

	 	•	 	 Explains the resolution of particular escalated trouble tickets to AT&T’s internal staff members when such an explanation may have the
potential for reducing the volume and categories of escalated trouble tickets. 

  

	4.1.2.3.	Service Responsibilities 

  

	 	•	 	 Uses and understands all Motricity service features that are available to the User. 

 

	4.1.2.4.	Technical Responsibilities 

  

	 	•	 	 Understands and is knowledgeable about problems that may arise during service usage. 

 

	 	•	 	 Understands and is knowledgeable with respect to functionality of supported handset models. 

 

	 	•	 	 Understands and is knowledgeable with email notification systems, the Internet and the World Wide Web. 

 

	 	•	 	 Understands and is knowledgeable with its network operations and is capable of discerning whether an incident is internal to its internal operations
before identifying the incident as a trouble ticket for Motricity. 

  

	4.1.3.	Incident Handling and Updates 

 The
Motricity Carrier Care Support Services group of Motricity will coordinate incident isolation, testing and repair work within Motricity and all contracted third party systems that are within Motricity’s Span of Control. During the incident
isolation and troubleshooting process, Motricity Carrier Care Support Services will communicate incident resolution progress with AT&T based upon the times specified in Table 4. Additionally, Motricity Carrier Care Support Services will
proactively inform AT&T when an issue or condition arises that may cause potential system anomalies and be a potential source for the creation trouble tickets. 

 

 26 

							
	 Motricity Incident
Level
	  	 Description
	  	 Update Method
	  	 Update

Objectives

	 Severity 1

(Sev1)

AT&T SIR1
	  	 Severity 1 problems are conditions that render the service inoperative and the inability to use the service has a critical effect on
operations. The condition is generally characterized by complete system failure and requires immediate restoration. Examples of this incident level being attained include:

 
 •     A
complete outage of critical service(s)
  

•     Loss of service or functionality feature that affects *** or more of
subscribers
  

•     A recurring anomaly impacting critical service(s).

 

•     Inability to provision a service.
	  	Email and phone	  	 First response within ***
  

First Update ***
  

Subsequent updates *** upon change in status.
  

Motricity will update AT&T with the information outlined in Appendix C.

				
	 Severity 2

(Sev2)

AT&T SIR2
	  	 Severity 2 problems are conditions under which the service is partially inoperative, but is still usable. The inoperative portion of the
service restricts operations but has a less critical effect than a Severity 1 condition. Examples of this incident level being attained include:
  

•     Loss of service and/or functionality that affects *** of the subscribers.

  

•     Loss of the ability to utilize some aspect of product features or
functionality.
	  	Email or phone	  	 First response ***
  

First update ***
  

Subsequent updates *** or upon change in status.
  

Motricity will update AT&T with the information outlined in Appendix C.

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 27 

							
				
	 Severity 3

(Sev3)

AT&T SIR3
	  	 Severity 3 problems are generally non-service affecting conditions under which the service is usable and either has no material affect
on operations or has very limited affect on operations. The condition is not critical to overall operations, and does not severely restrict such operations. Examples of this incident level being attained include:

 
 •     A minor
degradation of the service that affects *** or less of the subscribers.
  

•     Non-service impacting intermittent system faults.

 
 •     Loss of
resources / capacity / traffic measurement function.
  

•     Loss of reporting functionality.

 
 •     Invalid
measurement data.
	  	Email	  	 First response ***
  

First update within ***
  

Subsequent updates *** as agreed between the two parties.
  

Motricity will update AT&T with the information outlined in Appendix C.

Table 4, Incident Handling Notification Timetable 
  

	4.1.4.	Technical Bridge and Executive Bridge 

During the resolution of a service affecting incident, AT&T may establish a Technical Bridge and/or an Executive Bridge for any Incident. Motricity
shall join the Technical Bridge upon *** notice from AT&T for Severity 1 issues as noted in Table 5 below. These bridges are used for NOC-to- NOC communication, troubleshooting, triage and escalation. Unless otherwise notified by AT&T, a
Technical Bridge or Executive Bridge will be established as follows: 
  

							
	 Action
	 	 Sev 1
	 	 Sev 2
	 	 Sev 3

	Technical Bridge	 	*** when reasonably possible)	 	*** sooner upon request from AT&T)	 	*** sooner upon request from AT&T)
				
	Executive Bridge	 	***	 	***	 	N/A

 Table 5, Timelines for Technical and
Executive Bridges 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 28 

	4.1.5.	Escalation Procedures 

  

	4.1.5.1.	Motricity Internal Escalation  

Escalation procedures are in place at Motricity to manage the resolution of incidents when they occur. If a Severity 1 (Sev1) incident is not resolved
within *** of when Motricity was made aware of the problem, the incident will be escalated within Motricity to the dedicated Manager of Service Operations, who will drive escalation and resolution of the incident within Motricity’s Operations
and Engineering groups, and ensure that AT&T is kept updated with the incident resolution process. The appropriate Business Development person will also be informed of the occurrence and status of any Sev1 incident. If the Sev1 incident has not
been resolved by the Motricity & AT&T NOC teams within *** the Director of Commercial Operations will become directly involved with driving the incident to resolution and communicating with the appropriate AT&T personnel. The status
of the incident will also be communicated to senior management within Motricity. 
  

	4.1.5.2.	AT&T Escalation to Motricity 

 In the
event that Motricity does not respond to AT&T within the times shown in Table 4, AT&T can request that the incident be escalated to the next level, based on the contact information shared between the two companies (see Appendix A for a list
of names that are current as of time of the Effective Date). All escalation requests must be initiated through the 7x24 contact information provided in Table 1, and not to the individual directly. Only in the event that the 7x24 representative does
not escalate within *** should the appropriate Motricity individual be contacted directly. AT&T must verify that escalation has not taken place prior to calling any Motricity employee directly. 

For the purposes of clarification, Table 6 provides escalation timelines for Severity 1 and 2 incidents, based on time after the incident was reported.
Severity 3 incidents seldom require escalation but in the event that AT&T believes that Motricity is not addressing the incident in a timely manner, the parties can mutually agree to elevate the priority of the incident, and treat it as a
Severity 2 incident. 
  

							
	 Escalation Level
	 	 Escalation Contact
	 	 Severity 1
	 	 Severity 2

	Level 1	 	Carrier Specialist	 	***	 	***
				
	Level 2	 	Manager – Service Operations	 	***	 	***
				
	Level 3	 	Director – Commercial Operations	 	***	 	***

 Table 6, Escalation Timetable 

 

	4.1.5.3.	Additional Escalation Information 

Motricity and AT&T will ensure that any additional processes that are required to ensure the smooth escalation of incidents within each organization
are clearly communicated to one another in writing, so that the escalation processes within each organization and between the two organizations are clearly understood by both parties. 

Motricity and AT&T will exchange the names and contact information of the personnel who need to be kept informed of progress during the escalation
process in Appendix A. Both parties are responsible for ensuring that the contact information is updated and exchanged when circumstances warrant. This information will not be updated and kept current as part of this SLA, but will need to be
maintained separately by the two parties outside of this document. 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 29 

	4.2.	WAP Handsets for Incident and Problem Management 

In order for Motricity to provide the most effective level of support, AT&T agrees to provide Motricity with two (2) testing units for each
device type specifically for supporting Incident and Problem Management. Each such device shall be appropriately provisioned and have a valid account and password as to properly access the AT&T network. Each such unit shall be the GA (general
availability) version of the handset and should be supplied to Motricity no less than 30 days prior to launch. 
  

	5.	Incident Reporting Process 

  

	5.1.	Communicating Incidents 

 AT&T will
communicate incidents to Motricity in the following manner: 
  

	 	•	 	 Phone call to Motricity SOC or sends a trouble ticket to Motricity via email using the email address of carrier.care@Motricity.com.

  

	 	•	 	 Motricity sets the initial classification of their internal trouble ticket according to the AT&T notification (see “Mandatory
Information” below), unless otherwise agreed between Motricity and AT&T. 

  

	 	•	 	 Motricity will generate a single response for each trouble ticket that is received from AT&T, to confirm receipt of the incident report.

  

	5.1.1.	Mandatory Information for Incident Reporting 

For each AT&T originated incident, AT&T will make every effort to provide as much information to Motricity that will facilitate timely problem
determination and resolution. Upon notification of the incidents, the required information will be verified. When Motricity has received sufficient information, Motricity will begin resolving the incident and provide feedback to AT&T as
described above in Section 5.1 Communicating Incidents. 
 AT&T will use best efforts to provide Motricity the following information
via email for all reported incidents as required: 
  

	 	•	 	 Reference number assigned by AT&T. 

  

	 	•	 	 Motricity Service being used. 

  

	 	•	 	 System Identity number (usually phone number). 

  

	 	•	 	 Time and date of the transaction in question. 

  

	 	•	 	 Description of the incident. 

  

	 	•	 	 Severity of the incident or problem. 

  

	 	•	 	 List of specific steps to reproduce the problem if possible 

 

	 	•	 	 List of those actions taken by AT&T to verify the problem and that AT&T has attempted to resolve the incident. 

 

	 	•	 	 Other comments to provide additional information as needed. 

 

	 	•	 	 All communications that include references to time should be expressed using a 24-hour clock format and should always utilize and reference PST as the
standard time zone. 

  

 30 

	6.	Motricity Reports 

  

	6.1.	Post Mortem Reports 

 The purpose of the
Post-Mortem Report is to outline the known information regarding the incident and possible root causes and to summarize the incident resolution timeline. If known, it will also identify corrective actions to prevent its reoccurrence. Motricity will
create a Post-Mortem Report and provide such report to AT&T per Section 2.2.1. 
  

	6.2.	Service Level Reporting 

 Each month,
Motricity will provide AT&T with a “Monthly Service Level Report” indicating the service performance for the Services for the previous month (see SLA Monitoring Requirements (Appendix D) below for detailed list of Services associated
with this SLA). This report will contain performance reporting for the service performance objectives listed in Appendix D and a summary of the weekly incident response reports described in Section 6.3 for such month. 

Motricity shall supply the Monthly Service Level Report no later than the tenth business day of the month following the immediately preceding month. It
is agreed that Motricity will work towards publishing the Monthly Service Level Report on the sixth business day starting 6 months from the initial launch of Services. 

The Monthly Service Level Report shall include, among other things, the following information related to service availability for the Services listed in
Appendix D: 
  

	 	•	 	 Total minutes in the current month 

  

	 	•	 	 Total available minutes for the reported month for each Service 

 

	 	•	 	 Calculated Service Availability, presented as a percentage for each Service 

 

	 	•	 	 Target Service Level Availability for each Service 

  

	 	•	 	 Variance from Target Service Level for each Service 

  

	 	•	 	 Overall Service Level Availability for the Services 

The Monthly Service Level Report shall include, among other things, the following information related to latency for the Services listed in Appendix D:

 *** 
 The Monthly Service Level
Report shall also include, among other things, the following information for the Services listed in Appendix D: 
  

	 	•	 	 Appropriate performance metrics related to processing of
3rd party content feeds 

 

	 	•	 	 Overall Service Level Availability for Motricity contracted Third Party Content Providers 

 

	 	•	 	 Detailed log of all service impacting incidents for the month 

 

	6.3.	Open Issues List Reporting 

 Motricity
shall provide a weekly Open Issues Report, to be reviewed jointly with AT&T during the weekly Operations Call. Both parties agree to periodically review the appropriateness of the frequency of the Open Issues Report and Operations Call. This
report shall include the following information: 
  

	 	•	 	 Outage report including; 

  

	 	•	 	 Ticket Number 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission

  

 31 

	 	•	 	 Start time 

  

	 	•	 	 End time 

  

	 	•	 	 Resolution 

  

	 	•	 	 Severity level 

  

	 	•	 	 Impact 

  

	 	•	 	 Number of Reported Issues and brief summary of the issues 

 

	 	•	 	 Date that each Reported Issue was opened 

  

	 	•	 	 Current Reported Issue status, and if resolved, the date of the resolution. 

 

	 	•	 	 Total number and description of unresolved issues. 

  

	7.	Change Control Management (CCM) 

  

	7.1.	Planned Maintenance by Motricity 

Motricity will ensure that any planned maintenance events under its Span of Control will be executed in a well-coordinated manner. Proper execution
includes notification to AT&T by Motricity Carrier Care Support Services. 
  

	7.1.1.	Service Interruptions and Advanced Notification Requirements 

Motricity will provide AT&T with *** advance notice (via email) of all planned maintenance activities resulting or potentially resulting in service
interruptions that will have a direct impact on the Services unless otherwise mutually agreed by the parties. Motricity may assume that AT&T accepts the scheduled maintenance unless Motricity is advised via email within *** prior to the time of
the planned event. 
 Unless otherwise arranged, Motricity will perform planned service interruptions from *** (the “AT&T Maintenance
Window”) or as otherwise communicated between the two parties. Notwithstanding the foregoing, upon AT&T’s sole discretion, the AT&T Maintenance Window may be extended to allow for maintenance, testing and/or validation of the
Services that falls outside of the AT&T Maintenance Window 
 *** 

Please Note: *** Any Motricity unplanned system downtime resulting from a AT&T maintenance activity or otherwise required on account of
AT&T’s action(s) or inaction(s), will not be counted against the Motricity SLA service measures from the time the requested maintenance activity was scheduled through the end of that month. The outage and/or service degradation must be
directly attributable to the AT&T maintenance activities or otherwise required on account of AT&T’s action(s) or inaction(s). 
  

	7.1.2.	Communications Related to Planned Maintenance 

Motricity notification of planned maintenance will be communicated to AT&T through use of the Maintenance Request Worksheet shown in Appendix B.
Motricity will provide official notification to AT&T of the start and end of a planned maintenance activity via email to the contacts identified in Section 4.1.1. During all planned maintenance activities, AT&T will establish a
technical bridge for real time communication of status and progress, and Motricity will participate in that technical bridge unless otherwise agreed by both parties. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 32 

	7.1.3.	Canceling Planned Service Interruptions 

In the event of an AT&T emergency, AT&T may cancel the planned service interruption. Cancellation by AT&T may occur only if AT&T notifies
Motricity within one (1) business day of the scheduled start time of the maintenance window. Any notification of cancellation must come directly from either an Operations Manager or AT&T Team Leader via voice notification by calling *** for
local or International calls), with a follow-up email that should be sent to: 
 *** 

 

	7.1.4.	Restrictions Associated with AT&T’s Cancellation 

In the event that AT&T cancels a maintenance activity planned by Motricity, as defined in Section 7.1.1 above, and the parties are unable to
mutually agree on an alternative schedule, Motricity will not be held to the SLA service measures from the time the requested maintenance activity was scheduled through the end of that month. The outage and/or service degradation must be directly
attributable to the postponed maintenance activities. 
 If an alternative schedule is agreed upon, but a failure occurs between the originally
approved maintenance window and the rescheduled maintenance window, Motricity will not be held to the SLA services measures for that related outage and/or degradation. 
  

	7.1.5.	Planned Service Interruptions by AT&T 

AT&T will provide Motricity with advance notice (via email to ***) of all planned maintenance activities requiring support from Motricity. AT&T
will make every effort to provide *** advance notice and will provide at a minimum *** advance notice of such activities. Such planned activities will exclude changes to Motricity software and/or configurations as these would require additional
notice. 
  

	7.1.6.	Unplanned Service Interruptions by AT&T 

AT&T will notify Motricity of any unplanned service interruptions via email to Motricity Carrier Care (***) as quickly as is reasonably possible for
AT&T. 
 Motricity will make all reasonable efforts to support AT&T in resolving the issue. Motricity may charge its standard
professional services fees for such efforts. 
  

	7.1.7.	Splash Page During Maintenance 

 The
parties will cooperate to display a “splash page” during any planned or emergency maintenance that would otherwise result in a TCP timeout from a WAP Gateway and other mutually agreed required maintenance activities requiring customer
requests to be blocked whenever reasonably technically feasible. Such a page will be presented to users of both the wired and wireless web access points, to inform them of temporary unavailability of the Services. Service of the splash page does not
constitute availability, but is categorized as either planned or unscheduled service interruption (in accordance with Section 7.1). AT&T will provide the static WML/xHTML content to be displayed in the “splash page”. 

 

	7.2.	Capacity Planning Forecasts 

 To ensure
the highest level of service, Motricity requires AT&T at least twice per year to provide a forecast estimating the growth of their customer base (3, 6, 9 and 12 months into the future) and likely service usage. This will allow Motricity to plan
the required resources to support the services for AT&T’s customers. If 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commisson.

  

 33 

 AT&T becomes aware of any material changes that would impact any forecast previously provided to
Motricity (e.g., if AT&T has a special promotion plan in which a high number of new customers are anticipated), Motricity must be given 30 days advance notice of any change in the forecast to prepare for such additional capacity. If AT&T
fails to provide Motricity with such notice, Motricity will not be held responsible for any failures to the performance objectives that could have been avoided had Motricity received such notice. A forecast provided pursuant to this section is only
a forecast and is not a commitment on behalf of AT&T for the forecasted amount. 
  

	8.	Financial Consequences of Non-Performance 

  

	8.1.	Financial Consequences for Failure to Meet Service Objectives 

The following sections define financial penalties for non-performance related to service objectives within the Motricity Span of Control. 

These non-performance penalties set forth in this Section 8 will apply commencing on the date of commercial launch of the Services, unless the
parties agree in writing to delay the application of non-performance of penalties for a particular Service or Services. The total financial penalties owed to AT&T under the Agreement will be subject to the SLA penalty cap set forth in Table 7
below. For purposes of clarity the SLA penalty cap under this Exhibit G-2 is not in addition to any other SLA exhibit. 
  

							
	 Effective date
	  	 	  	 SLA Penalty Cap
	  	 
	***	  		  	***	  	

 Table 7, Penalty Cap Phase-In Schedule 

For the purposes of the SLA, Motricity “Total Revenue” shall be calculated as follows: the sum of the *** For further detail regarding the
non-performance penalties described below, reference SLA Penalty Calculation Model (Appendix E) below. 
 For any month for which there is an
Availability and a Latency penalty due for the same period of time, Motricity shall be required to pay only the Availability penalty and the Latency penalty shall be waived when mutually agreed that there was a common or related cause. 

Motricity will deduct penalties for non-performance from the subsequent month’s invoice to AT&T for the Services. 

 

	8.2.	Service Availability 

  

	(a)	Service availability targets apply to Services provided to AT&T as described in the SLA Monitoring Requirements (Appendix D) below and will be reported as required
in Section 6 above. : 

  

							
	 Service Area
	  	 	  	 ***
	  	  
	***	  		  	***	  	
	***	  		  	***	  	
	***	  		  	***	  	

 Table 8, Service Availability Penalty Calculation 

 

	(b)	Subject to Section 8.1, Motricity agrees to pay to AT&T service availability failure fees computed on a monthly basis, as a calculation of (i) plus (ii):

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 34 

	i.	*** 

  

	ii.	*** 

 Motricity will utilize the most recent and
relevant historical user data available for the purpose of determining the percentage of users impacted during periods of unavailability. 
  

	8.3.	Service Latency 

 Service latency targets
apply to Services provided to AT&T as described in Appendix D and will be reported as required in Section 6 above. Notwithstanding the foregoing, non-performance penalties will apply solely to the following portions of the Services as
further described in Appendix D: 
  

					
	 	 	 ***
	 	 

 Table 9, Latency Penalty Calculation 

Subject to Section 8.1, Motricity agrees to pay to AT&T excessive latency fees based on performance according to Table 9 above
for each month of the SLA reporting period. In the event the monthly latency measurement for a particular Service Area listed in Table 2 above exceeds *** 
  

	8.4	*** 

  

	8.5	*** 

  

	9.	Right to Terminate 

  

	(a)	Right to Terminate for Failure to Meet Monthly Service Availability Requirement. 

In the event that the monthly service availability target described in Section 3.1 is not met for the Service Areas listed in
Section 8.2 above in any three calendar months within any four month period during the Term, then, at the end of any such third failed month, AT&T shall have the 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 35 

 right, in its sole discretion, to terminate the Agreement for cause upon thirty
(30) days prior written notice to Motricity or to provide Motricity notice of AT&T’s intent to develop a “Get Well Plan.” In the event that AT&T delivers a “Get Well Plan” notice, the parties will use good faith
efforts to agree to and execute on a plan for Motricity to remedy the applicable performance failures and meet the service availability target set forth in Section 3.1. Upon implementation of any such mutually agreed plan, a new four month
measurement period to determine compliance with the service availability requirement will commence. 
  

	(b)	Right to Terminate for Failure to Meet Latency Requirement. 

In the event that the latency requirement described in Section 3.2 is not met for the Service Areas listed in Section 8.3 above
in any three calendar months within any four month period, then, at the end of any such third failed month, AT&T shall have the right, in its sole discretion, to terminate the Agreement for cause upon thirty (30) days prior written notice
to Motricity or to provide Motricity notice of AT&T’s intent to develop a “Get Well Plan.” In the event that AT&T delivers a “Get Well Plan” notice, the parties will use good faith efforts to agree to and execute on
a plan for Motricity to remedy the applicable performance failures and meet the service latency target set forth in Section 3.2. Upon implementation of any such mutually agreed plan, a new four month measurement period to determine compliance
with the service availability requirement will commence. 
  

 36 

 Appendix A – Contact & Escalation List 

Both parties are responsible for ensuring that the contact information is updated and exchanged when circumstances warrant. This information will not be
updated and kept current as part of this SLA, but will need to be maintained separately by the two parties outside of this document. 

Motricity Customer Care Contact Information 
  

			
	 Primary Contact (Single Point of Contact) 24 X 7

		
	 Contact Name
	  	Service Operations Center (SOC) / Carrier Care
		
	 Title
	  	N/A
		
	 Phone
	  	***
		
	 Email
	  	***
		
	 Level 1 Escalation
	  	
		
	 Contact Name
	  	***
		
	 Title
	  	Manager, Service Operations
		
	 Phone
	  	***
		
	 Email
	  	***
		
	 Level 2 Escalation
	  	
		
	 Contact Name
	  	***
		
	 Title
	  	Director, Commercial Operations
		
	 Phone
	  	***
		
	 Email
	  	***
		
	 Level 3 Escalation
	  	
		
	 Contact Name
	  	***
		
	 Title
	  	Sr. Director - Systems & Network Operations
		
	 Phone
	  	***
		
	 Email
	  	***

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commisson.

  

 37 

 AT&T Contact Information 

 

							
	 AT&T
	  	 Hours of Operation
	  	 Role
	  	 Phone/Email

	NSD National Operations Center	  	24 x 7 x 365	  	Incident Management and Emergency Maintenance	  	***
				
	MMS External Partner Ops	  	8:00 am – 5:00 pm PT Monday – Friday	  	Incident Root Cause Analysis, Change Management, Performance Reports and Tier 2 Support	  	***
				
	Change Management	  	8:00 am – 5:00 pm PT Monday – Friday	  	Maintenance Notification – all maintenance	  	***

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commisson.

  

 38 

 Appendix B – Maintenance Request Worksheet 

This Maintenance Request Worksheet is be sent to: *** and *** 

 

	1)	Title of Maintenance 

  

	2)	Brief Description of Maintenance 

  

	 	•	 	 Scope and full description 

  

	 	•	 	 AT&T service 

  

	3)	Maintenance Start Date & Time 

  

	4)	Maintenance End Date & Time 

  

	5)	AT&T Service Impact 

  

	 	•	 	 Impact to AT&T internal & external customers 

 

	 	•	 	 Explanation of Information Service unavailability 

  

	6)	Information Service Impact Assessment (within the scheduled window) 

  

	 	•	 	 Duration in minutes 

  

	 	•	 	 Estimated start/end time of AT&T service impact 

  

	7)	Risk Assessment 

  

	8)	Partner Maintenance Request Number 

  

	9)	Point of Contact 

  

	 	•	 	 Name, telephone numbers 

  

	10)	Maintenance Install Team 

  

	11)	Update Schedule 

  

	 	•	 	 Cancellation of Maintenance – as soon as possible 

 

	 	•	 	 Start of Maintenance Window 

  

	 	•	 	 Notify when Down Time begins 

  

	 	•	 	 Notify when Information Service is restored (Down Time ends) 

 

	 	•	 	 Notify of Problem 

  

	 	•	 	 Maintenance runs outside window 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 39 

 Appendix C – Incident Notification 

Incident Notification or Trouble Ticket (send to: ***) 
  

	1)	Title of Incident 

  

	2)	Brief Description of Incident 

  

	 	•	 	 Should include scope (AT&T service impacted) 

  

	3)	Start Date and Time 

  

	4)	Information Service Resolution Date and Time 

  

	5)	Duration of Outage 

  

	 	•	 	 Provided at time of restoration 

  

	6)	AT&T Information Service Impact 

  

	 	•	 	 Impact to AT&T End Customer 

  

	7)	Partner Ticket Number 

  

	8)	Partner Severity Level 

  

	 	•	 	 Based on quantified Information Service impact 

  

	9)	Technical Action Take to Correct Incident 

  

	 	•	 	 Steps taken to restore Information Service 

  

	10)	Initial Root Cause 

  

	 	•	 	 Suspect root cause (brief) 

  

	 	•	 	 Formal RCA for SIR 1 or chronic issues of lower severity 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 40 

 Appendix D – SLA Monitoring Requirements 

*** 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 41 

 Appendix E – Media Net SLA Penalty Calculation Model 

*** 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 49 

 EXHIBIT G-2 – SERVICE LEVEL AGREEMENT – WEB BASED SERVICES 

 

	1.	General Information 

  

	1.1.	Purpose 

 The purpose of this document is
to identify the levels of service that will be maintained by Motricity and to provide this information to operations personnel of both parties responsible for the monitoring and/or support of the Services. 

 

	1.2.	Scope 

 This Service Level Agreement (SLA)
describes the basic level of service that will be provided by Motricity in its support of the delivery of the Services to AT&T for WEB based applications (‘“WEB Services”). For purposes of clarity reference to Service in this SLA
means the WEB Services. 
 This agreement describes the requirements for the following: 

 

	 	f)	support and maintenance of all Motricity and third-party hardware and software for the Services 

 

	 	g)	7x24x365 support and response requirements for support calls; 

  

	 	h)	fixes, patches, and minor enhancements; 

  

	 	i)	new software releases that contain fixes to defects in production feature functionality; and 

 

	 	j)	on-site resources to support acceptance testing, trouble shooting, and system upgrades. 

This SLA also defines requirements for response (including email, telephone, remote, and on-site) and resolution timeframes related to Severity 1,
Severity 2, and Severity 3 incidents, as well as non-performance financial penalties which will be owed to AT&T for failures to meet certain obligations defined herein. 

This document also defines expectations relating to: 
  

	 	•	 	 Motricity and AT&T Responsibilities with respect to the Services 

 

	 	•	 	 Service Performance Objectives 

  

	 	•	 	 Incident Management 

  

	 	•	 	 Incident Reporting Process 

  

	 	•	 	 Operational Reports 

  

	 	•	 	 Change Control Management 

This document should be used as a reference for AT&T’s Network Operations and its contracted affiliates and Motricity in support of the
Services. It provides the framework for surveillance, isolation, analysis, and resolution of problems related to the Services. 
 As a means to
ensure the highest level of accuracy and efficiency for both AT&T and Motricity, this SLA supersedes all existing Service Level Agreements relating to the Services. 

For a complete list of the Services that are subject to this SLA, see the SLA Monitoring Requirements (Appendix D) below. 

 

	1.3.	Out of Scope 

 The following items are deemed to
be outside the scope of this SLA; however, both parties will make a good faith effort to establish the following independently from this SLA. 
  

 50 

 *** 
  

	1.4.	Definitions 

 For purposes
of this SLA, following definitions apply: 
 Service Area refers to the specific Service components for which financial
consequences for non-performance apply under this SLA. 
 My MEdia Net Login Page is a Service Area that refers to the
specific login web page for My MEdia Net. 
 My MEdia Net Home Page is a Service Area that refers to the specific web page
that a User views after the My MEdia Net Login Page. 
 My MEdia Net Category Applications is a Service Area that refers
to the MEdia Net Service applications provided to AT&T by Motricity and/or hosted by Motricity for AT&T since November 17, 2005. 

“MEdia Net Active Links” or “Active Links” is a Service Area that means links which can be added to a
User’s MEdia Net Home Page, can be either dynamic or static. Dynamic Active Links are those which contain both category links and dynamic content which is updated periodically throughout the day. Static Active Links are bookmarks which do not
contain feed-driven dynamic content (also referred to as “Bubbles.”) 
 “WEB Application(s)” means the
MEdia Net software applications that are accessed via a personal computer. 
 “WEB Application User Ratio” as
used in Section 8 is calculated on a monthly basis by dividing the number of unique WEB Application Users by the number of unique MEdia Net Users that customize the like-for-like MEdia Net Service via the MEdia Net WAP Services. 

 

	2.	Responsibilities and Services 

 This
Section 2 describes Motricity’s support responsibilities with respect to the Services, and the corresponding responsibilities of AT&T. 
  

	2.1.	Motricity Responsibilities 

 Motricity
will provide day-to-day service operations, maintenance and administration in support of the Services that are within Motricity’s Span of Control, as described below. 

Span of Control is defined as those areas of functionality that are under the direct control of Motricity. This includes functionality that is provided
by external vendors or suppliers with whom Motricity has a contractual relationship, including feeds from providers of Motricity Sourced Content. 

It is the intention of Motricity to expeditiously remedy incidents that have been identified either internally by Motricity or AT&T. Corrective
action by Motricity assumes that the incident is within its Span of Control and AT&T has provided all relevant information, if available, to Motricity. See the section entitled Mandatory Information for Incident Reporting for required
reporting information. 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 51 

 Motricity will pursue the resolution of an incident with outside vendors provided Motricity has a
contractual arrangement with the vendor. During the resolution period, Motricity will issue updates to AT&T pursuant to the severity of the incident, as described later in this document. 

Any third party content provider contracted directly by AT&T is not a party to this agreement. Any loss of content from such providers is outside of
Motricity’s Span of Control. 
  

	2.2.	Motricity Carrier Care 

 The Motricity
Carrier Care Support Services team is an interface between AT&T’s Level 2 Support Group (AT&T’s non-customer facing group) and Motricity for support of services provided by Motricity. This arrangement provides AT&T with access
to a single point of contact for reporting incidents, receiving updates and escalation. Table 1 provides the Motricity Carrier Care hours of operation and contact information. A complete list of all contacts is also shown in Appendix
A. These contacts are to be contacted per the escalation procedures outlined in Section 3. 
  

			
	 Hours of Operation
	  	24 hours a day, 7 days a week and 365 days a year (7/24/365)
		
	 Contact Phone Number
	  	***
		
	 Email Address
	  	***

 Table 1, Motricity Carrier Care Contact
Information 
  

	2.2.1.	Motricity Support Services 

 The following
list identifies services that are offered by Motricity Support Services to AT&T: 
  

	 	•	 	 Telephone and email support for incident resolution 

  

	 	•	 	 Advisory Bulletins 

  

	 	•	 	 Notification of planned maintenance activities 

  

	 	•	 	 Post Mortem Reports for Severity 1 (SEV1) and recurring incidents classified as Severity 2 (Sev2) including a Root Cause Analysis (RCA) upon request.
*** 

  

	2.2.2.	PC Pages Support 

 As applicable, the PC
Pages related Services will operate on browsers that are HTML 4.0 Compliant, specifically, Internet Explorer (IE) 5.0 and above. Motricity will make commercially reasonable efforts to support other browsers that demonstrate significant market
presence. 
  

	2.3.	AT&T Responsibilities 

 AT&T will
provide support for Incident Management as detailed in Section 4. 
  

	3.	Service Performance Objectives 

  

	3.1	Service Availability 

 Service
Availability (SA) is defined as the amount of time the Service is up excluding planned Maintenance and AT&T caused outages, computed as: 

*** 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 52 

 The above calculations allow a weighting for partial outages and degraded service, such that only the
fraction of Users denied service contributes to negative Service Availability. 
 For purposes of clarity where the Service is
“available” but in a cached state it is considered inoperable and the SLA non-performance penalties will be applicable as set forth herein. 
  

	3.1.1	Service Availability Target  

Motricity shall provide an overall system service availability of *** for all Services listed in the SLA Monitoring Requirements (Appendix D)
below, measured at no less than the frequency shown in Appendix D and reported at monthly intervals as described in Section 6.2 below. This measurement excludes downtimes caused by AT&T and service interruptions due to planned
maintenance approved in advance by AT&T. 
  

	3.2	Service Latency 

 User requests for
Services shall be fulfilled in accordance with Table 2 below for each calendar month. This includes delivery of all bytes of the response (content plus protocol overhead) that Motricity controls (i.e. service requests and subsequent requests for
which the browser’s URL target is hosted by Motricity). 
 Motricity will achieve the latency targets set forth in Table 2 below on the
schedule set forth in Table 2. The parties agree to review such latency targets from time to time during the Term and to assess whether to adjust the latency. Unless otherwise mutually agreed, these are the targets for penalties as set forth in
Section 8.3. 
 Table 2, Latency Target Ramp 
  

									
	 ***
	  	 	  	 	  	 	  	 

 These requirements are specific to the portion of end to end Latency incurred within
the Motricity’s Span of Control and will be measured from the secure network nearest the Motricity border router. The design of latency monitoring infrastructure will ensure appropriate components of the request and response are adequately
measured. The implementation of latency monitoring infrastructure will include the deployment of a separate and specific server(s) for the purpose of monitoring and fault management. The latency introduced by the GPRS network, the WAP Gateway and
other elements of the AT&T Network are excluded from the latency measurements described above. 
  

	3.3	Legacy Components Supporting MEdia Net 

The following Legacy Services will not be held to the Service Availability as noted above but will meet the legacy Service Availability of *** basis as
set forth below: 
 *** 
 Service
Availability (SA) is defined as the amount of time the service is up excluding planned Maintenance and AT&T caused outages, computed as: 

*** 
 The above calculations allow a weighting
for partial outages and degraded service, such that only the fraction of Users denied service contributes to negative Service Availability. 
  

	3.4	*** 

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 53 

	3.5	Third-Party Content Providers 

 Motricity
will be responsible for the performance, service availability and service latency of all providers of Motricity Sourced Content with whom Motricity has a contract. Where such content provider contracts exist, Motricity will perform appropriate
alarming, monitoring and fault management to ensure that performance of these providers fully supports the service objectives defined in this SLA. Motricity will also identify those content providers to AT&T and provide notification of changes
to such contractual relationships no less than 30 days in advance of such changes becoming effective. 
 Expectations for processing of third
party content feeds as set forth in Appendix D are as follows: For streaming content (sports scores and stock quotes) and breaking news, all received content must be processed and published a maximum of *** For all other content feeds that
are updated at least once a day, content must be processed and published within *** For all other content feeds (those updated less frequently than once per day), the content must be processed and published as soon as possible, and will at all times
display content for the current day. 
 Motricity will also provide monthly reporting of service interruptions, availability measures and other
data for contracted providers of Motricity Sourced Content in accordance with Section 6. 
 In addition, Motricity will be
responsible for all degradations and service impacting issues affecting the Services that are caused by providers of Motricity Sourced Content from a Motricity SLA performance perspective. 

 

	4.	Incident Management 

  

	4.1.	Incident Resolution Responsibilities 

Incident resolution requires teamwork between Motricity and AT&T. A key element in this teamwork approach is AT&T’s understanding of the User
service(s) offered by Motricity. 
 All AT&T identified incidents concerning failures of the Services that cannot be solved by AT&T
representatives will be reported to Motricity Carrier Care Support Services, pursuant to the Reporting Process procedures outlined below. AT&T will assign a Severity Level per Table 4. If Motricity disagrees with the Severity assignment,
both parties will negotiate in good faith after the resolution of the incident but all restoration will proceed based upon AT&T’s initial Severity assignment. 

Any reported incident that is caused by a failure that is outside Motricity’s Span of Control and not directly related to its delivery of a
subscriber service will be returned to AT&T with an appropriate explanation. Should Motricity determine that an incident being worked by Motricity Carrier Care Support Services is within AT&T’s control, the incident will be closed and
returned to AT&T for proper resolution. 
  

	4.1.1.	AT&T Contact Information 

 In order
for Motricity Carrier Care to effectively resolve Incidents, it is necessary for Motricity to have an accurate list of AT&T’s designated key personnel. This information will be exchanged between the two parties and updated as changes
warrant. Appendix A shows the type of contact information required, showing the current contacts at the Effective Date. This data will be maintained and updated by the two parties outside of this SLA document. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 54 

							
	 AT&T
	  	 Hours of Operation
	  	 Role
	  	 Phone/Email

	NSD National Operations Center	  	24 x 7 x 365	  	Incident Management and Emergency Maintenance	  	***
				
	MMS External Partner Ops	  	8:00 am – 5:00 pm PT Monday – Friday	  	Incident Root Cause Analysis, Change Management, Performance Reports and Tier 2 Support	  	***
				
	Change Management	  	8:00 am – 5:00 pm PT Monday – Friday	  	Maintenance Notification – all maintenance	  	***

 Table 3, AT&T Contact Information 

 

	4.1.2.	AT&T Responsibilities 

 The following
section identifies the responsibilities of AT&T as it relates to this Service Level Agreement. 
  

	4.1.2.1.	General Responsibilities 

  

	 	•	 	 Acts as the primary and direct contact with the User. 

 

	 	•	 	 Answers simple questions and resolves minor issues such as resetting passwords or creating new User accounts. 

 

	4.1.2.2.	Incident Responsibilities 

  

	 	•	 	 Creates a trouble ticket that clearly states the problem after gathering all pertinent information about the incident including name, User number,
password and any other additional information that is important to resolution of the incident. 

  

	 	•	 	 Records any subsequent conversation with the User relative to the incident in the same trouble ticket. 

 

	 	•	 	 “Owns” the resolution of an incident by coordinating its resolution within AT&T operational and technical environment and with Motricity
or its designees. 

  

	 	•	 	 Resolves the incident with the User or determines that the capability is outside the scope of current functionality. 

 

	 	•	 	 Explains the resolution of the incident to a technical peer or is capable of targeting the root technical problem for resolution.

  

	 	•	 	 Describes the incident in technical terms to an engineer or developer who is responsible for resolution of the incident. 

 

	 	•	 	 Explains the resolution of particular escalated trouble tickets to AT&T’s internal staff members when such an explanation may have the
potential for reducing the volume and categories of escalated trouble tickets. 

  

	4.1.2.3.	Service Responsibilities 

  

	 	•	 	 Uses and understands all Motricity service features that are available to the User. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 55 

	4.1.2.4.	Technical Responsibilities 

  

	 	•	 	 Understands and is knowledgeable about problems that may arise during service usage. 

 

	 	•	 	 Understands and is knowledgeable with respect to functionality of supported handset models. 

 

	 	•	 	 Understands and is knowledgeable with email notification systems, the Internet and the World Wide Web. 

 

	 	•	 	 Understands and is knowledgeable with its network operations and is capable of discerning whether an incident is internal to its internal operations
before identifying the incident as a trouble ticket for Motricity. 

  

	4.1.3.	Incident Handling and Updates 

 The
Motricity Carrier Care Support Services group of Motricity will coordinate incident isolation, testing and repair work within Motricity and all contracted third party systems that are within Motricity’s Span of Control. During the incident
isolation and troubleshooting process, Motricity Carrier Care Support Services will communicate incident resolution progress with AT&T based upon the times specified in Table 4. Additionally, Motricity Carrier Care Support Services will
proactively inform AT&T when an issue or condition arises that may cause potential system anomalies and be a potential source for the creation trouble tickets. 

 

 56 

							
	 Motricity
Incident Level
	  	 Description
	  	Update
Method	  	 Update

Objectives

	 Severity 1

(Sev1)
 AT&T SIR1
	  	 Severity 1 problems are conditions that render the service inoperative and the inability to use the service has a critical effect on
operations. The condition is generally characterized by complete system failure and requires immediate restoration. Examples of this incident level being attained include:

 
 •     A
complete outage of critical service(s)
  

•     Loss of service or functionality feature that *** or more of
subscribers
  

•     A recurring anomaly impacting critical service(s).

 

•     Inability to provision a service.

 
 CPS and Care Tools which are not customer facing are not included in this definition.

	  	Email
and
phone	  	 First response within ***
  

First Update within ***
  

Subsequent updates *** or upon change in status.
  

Motricity will update AT&T with the information outlined in Appendix C.

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 57 

							
	 Severity 2
 (Sev2)

AT&T SIR2
	  	 Severity 2 problems are conditions under which the service is partially inoperative, but is still usable. The inoperative portion of the
service restricts operations but has a less critical effect than a Severity 1 condition. Examples of this incident level being attained include:
  

•     Loss of service and/or functionality that affects *** of the subscribers.

  

•     Loss of the ability to utilize some aspect of product features or
functionality.
  

•     A complete outage of a CPS or Care Tools
	  	Email
or
phone	  	 First response within ***
  

First update within ***
  

Subsequent updates *** or upon change in status.
  

Motricity will update AT&T with the information outlined in Appendix C.

				
	 Severity 3
 (Sev3)

AT&T SIR3
	  	 Severity 3 problems are generally non-service affecting conditions under which the service is usable and either has no material affect
on operations or has very limited affect on operations. The condition is not critical to overall operations, and does not severely restrict such operations. Examples of this incident level being attained include:

 
 •     A minor
degradation of the service that affects *** or less of the subscribers.
  

•     Non-service impacting intermittent system faults.

 
 •     Loss of
resources / capacity / traffic measurement function.
  

•     Loss of reporting functionality.

 
 •     Invalid
measurement data.
  

•     Web interface defects that have little or no impact on a User’s ability
to utilize service features and functions.
	  	Email	  	 First response within ***
  

First update within ***
  

Subsequent updates *** as agreed between the two parties.
  

Motricity will update AT&T with the information outlined in Appendix C.

Table 4, Incident Handling Notification Timetable 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 58 

	4.1.4.	Technical Bridge and Executive Bridge 

During the resolution of a service affecting incident, AT&T may establish a Technical Bridge and/or an Executive Bridge for any Incident. Motricity
shall join the Technical Bridge upon fifteen (15) minutes notice from AT&T for Severity 1 issues as noted in Table 5 below. These bridges are used for NOC-to-NOC communication, troubleshooting, triage and escalation. Unless otherwise
notified by AT&T, a Technical Bridge or Executive Bridge will be established as follows: 
  

							
	 Action
	  	 Sev 1
	  	 Sev 2
	  	 Sev 3

	Technical Bridge	  	*** when reasonably possible)	  	*** (or sooner upon request from AT&T)	  	*** (or sooner upon request from AT&T)
				
	Executive Bridge	  	***	  	***	  	N/A

 Table 5, Timelines for Technical and Executive
Bridges 
  

	4.1.5.	Escalation Procedures 

  

	4.1.5.1. 	Motricity Internal Escalation 

 Escalation
procedures are in place at Motricity to manage the resolution of incidents when they occur. If a Severity 1 (Sev1) incident is not resolved within *** of when Motricity was made aware of the problem, the incident will be escalated within Motricity
to the dedicated Manager of Service Operations, who will drive escalation and resolution of the incident within Motricity’s Operations and Engineering groups, and ensure that AT&T is kept updated with the incident resolution process. The
appropriate Business Development person will also be informed of the occurrence and status of any Sev1 incident. 
 If the Sev1 incident has not
been resolved by the Motricity & AT&T NOC teams *** the Director of Commercial Operations will become directly involved with driving the incident to resolution and communicating with the appropriate AT&T personnel. The status of the
incident will also be communicated to senior management within Motricity. 
  

	4.1.5.2. 	AT&T Escalation to Motricity 

 In the
event that Motricity does not respond to AT&T within the times shown in Table 4, AT&T can request that the incident be escalated to the next level, based on the contact information shared between the two companies (see Appendix
A for a list of names that are current as of time of the Effective Date). All escalation requests must be initiated through the 7x24 contact information provided in Table 1, and not to the individual directly. Only in the event that the
7x24 representative does not escalate within *** should the appropriate Motricity individual be contacted directly. AT&T must verify that escalation has not taken place prior to calling any Motricity employee directly. For the purposes of
clarification, Table 6 provides escalation timelines for Severity 1 and 2 incidents, based on time after the incident was reported. Severity 3 incidents seldom require escalation but in the event that AT&T believes that Motricity is not
addressing the incident in a timely manner, the parties can mutually agree to elevate the priority of the incident, and treat it as a Severity 2 incident. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 59 

							
	 Escalation Level
	  	 Escalation Contact
	  	Severity 1	  	Severity 2
	Level 1	  	Carrier Specialist	  	***	  	***
				
	Level 2	  	Manager – Service Operations	  	***	  	***
				
	Level 3	  	Director – Commercial Operations	  	***	  	***

 Table 6, Escalation Timetable 

 

	4.1.5.3. 	Additional Escalation Information 

Motricity and AT&T will ensure that any additional processes that are required to ensure the smooth escalation of incidents within each organization
are clearly communicated to one another in writing, so that the escalation processes within each organization and between the two organizations are clearly understood by both parties. 

Motricity and AT&T will exchange the names and contact information of the personnel who need to be kept informed of progress during the escalation
process in Appendix A. Both parties are responsible for ensuring that the contact information is updated and exchanged when circumstances warrant. This information will not be updated and kept current as part of this SLA, but will need to be
maintained separately by the two parties outside of this document. 
  

	5.	Incident Reporting Process 

  

	5.1.	Communicating Incidents 

 AT&T will
communicate incidents to Motricity in the following manner: 
  

	 	•	 	 Phone call to Motricity SOC or sends a trouble ticket to Motricity via email using the email address of ***.  

 

	 	•	 	 Motricity sets the initial classification of their internal trouble ticket according to the AT&T notification (see “Mandatory
Information” below), unless otherwise agreed between Motricity and AT&T. 

  

	 	•	 	 Motricity will generate a single response for each trouble ticket that is received from AT&T, to confirm receipt of the incident report.

  

	5.1.1.	Mandatory Information for Incident Reporting 

For each AT&T originated incident, AT&T will make every effort to provide as much information to Motricity that will facilitate timely
problem determination and resolution. Upon notification of the incidents, the required information will be verified. When Motricity has received sufficient information, Motricity will begin resolving the incident and provide feedback to AT&T as
described above in Section 5.1 Communicating Incidents. 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 60 

 AT&T will use best efforts to provide Motricity the following information via email for all reported
incidents as required: 
  

	 	•	 	 Reference number assigned by AT&T. 

  

	 	•	 	 Motricity Service being used. 

  

	 	•	 	 System Identity number (usually phone number). 

  

	 	•	 	 Time and date of the transaction in question. 

  

	 	•	 	 Description of the incident. 

  

	 	•	 	 Severity of the incident or problem. 

  

	 	•	 	 List of specific steps to reproduce the problem if possible 

 

	 	•	 	 List of those actions taken by AT&T to verify the problem and that AT&T has attempted to resolve the incident. 

 

	 	•	 	 Other comments to provide additional information as needed. 

 

	 	•	 	 All communications that include references to time should be expressed using a 24-hour clock format and should always utilize and reference PST as the
standard time zone. 

  

	6.	Motricity Reports 

  

	6.1.	Post Mortem Reports 

 The purpose of the
Post-Mortem Report is to outline the known information regarding the incident and possible root causes and to summarize the incident resolution timeline. If known, it will also identify corrective actions to prevent its reoccurrence. Motricity will
create a Post-Mortem Report and provide such report to AT&T per Section 2.2.1. 
  

	6.2.	Service Level Reporting 

 Each
month, Motricity will provide AT&T with a “Monthly Service Level Report” indicating the service performance for the Services for the previous month (see SLA Monitoring Requirements (Appendix D) below for detailed list of
Services associated with this SLA). This report will contain performance reporting for the service performance objectives listed in Appendix D and a summary of the weekly incident response reports described in Section 6.3 for such
month. 
 Motricity shall supply the Monthly Service Level Report no later than the tenth business day of the month following the immediately
preceding month. It is agreed that Motricity will work towards publishing the Monthly Service Level Report on the sixth business day starting 6 months from the initial launch of Services. 

The Monthly Service Level Report shall include, among other things, the following information related to service availability for the Services listed in
Appendix D: 
  

	 	•	 	 Total minutes in the current month 

  

	 	•	 	 Total available minutes for the reported month for each Service 

 

	 	•	 	 Calculated Service Availability, presented as a percentage for each Service 

 

	 	•	 	 Target Service Level Availability for each Service 

  

	 	•	 	 Variance from Target Service Level for each Service 

  

	 	•	 	 Overall Service Level Availability for the Services 

  

 61 

 The Monthly Service Level Report shall include, among other things, the following information related to
latency for the Services listed in Appendix D: 
 *** 

The Monthly Service Level Report shall also include, among other things, the following information for the Services listed in Appendix D:

  

	 	•	 	 Detailed log of all service impacting incidents for the month 

 

	 	•	 	 Service levels achieved for Users of the PC Pages and Users of the Phone Pages as listed in Section 3.3 above.

  

	6.3.	Open Issues List Reporting 

 Motricity
shall provide a weekly Open Issues Report, to be reviewed jointly with AT&T during the weekly Operations Call. Both parties agree to periodically review the appropriateness of the frequency of the Open Issues Report and Operations Call. This
report shall include the following information: 
  

	 	•	 	 Outage report including; 

  

	 	•	 	 Ticket Number 

  

	 	•	 	 Start time 

  

	 	•	 	 End time 

  

	 	•	 	 Resolution 

  

	 	•	 	 Severity level 

  

	 	•	 	 Impact 

  

	 	•	 	 Number of Reported Issues and brief summary of the issues 

 

	 	•	 	 Date that each Reported Issue was opened 

  

	 	•	 	 Current Reported Issue status, and if resolved, the date of the resolution. 

 

	 	•	 	 Total number and description of unresolved issues. 

  

	7.	Change Control Management (CCM) 

  

	7.1.	Planned Maintenance by Motricity 

Motricity will ensure that any planned maintenance events under its Span of Control will be executed in a well-coordinated manner. Proper execution
includes notification to AT&T by Motricity Carrier Care Support Services. 
  

	7.1.1.	Service Interruptions and Advanced Notification Requirements 

Motricity will provide AT&T with *** advance notice (via email) of all planned maintenance activities resulting or potentially resulting in service
interruptions that will have a direct impact on the Services unless otherwise mutually agreed by the parties. Motricity may assume that AT&T accepts the scheduled maintenance unless Motricity is advised via email within *** prior to the time of
the planned event. 
 Unless otherwise arranged, Motricity will perform planned service interruptions *** (the “AT&T Maintenance
Window”) or as otherwise communicated between the two parties. Notwithstanding the foregoing, upon AT&T’s sole discretion, the AT&T Maintenance Window may be extended to allow for maintenance, testing and/or validation of the
Services that falls outside of the AT&T Maintenance Window. 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 62 

 *** 

Please Note: *** Any Motricity unplanned system downtime resulting from a AT&T maintenance activity or otherwise required on
account of AT&T’s action(s) or inaction(s), will not be counted against the Motricity SLA service measures from the time the requested maintenance activity was scheduled through the end of that month. The outage and/or service degradation
must be directly attributable to the AT&T maintenance activities or otherwise required on account of AT&T’s action(s) or inaction(s). 
  

	7.1.2.	Communications Related to Planned Maintenance 

Motricity notification of planned maintenance will be communicated to AT&T through use of the Maintenance Request Worksheet shown in Appendix
B. Motricity will provide official notification to AT&T of the start and end of a planned maintenance activity via email to the contacts identified in Section 4.1.1. During all planned maintenance activities, AT&T will
establish a technical bridge for real time communication of status and progress, and Motricity will participate in that technical bridge unless otherwise agreed by both parties. 

 

	7.1.3.	Canceling Planned Service Interruptions 

In the event of an AT&T emergency, AT&T may cancel the planned service interruption. Cancellation by AT&T may occur only if AT&T notifies
Motricity within one (1) business day of the scheduled start time of the maintenance window. Any notification of cancellation must come directly from either an Operations Manager or AT&T Team Leader via voice notification by calling
*** for local or International calls), with a follow-up email that should be sent to: 
 *** 

 

	7.1.4.	Restrictions Associated with AT&T’s Cancellation 

In the event that AT&T cancels a maintenance activity planned by Motricity, as defined in Section 7.1.1 above, and the parties are unable
to mutually agree on an alternative schedule, Motricity will not be held to the SLA service measures from the time the requested maintenance activity was scheduled through the end of that month. The outage and/or service degradation must be directly
attributable to the postponed maintenance activities. 
 If an alternative schedule is agreed upon, but a failure occurs between the originally
approved maintenance window and the rescheduled maintenance window, Motricity will not be held to the SLA services measures for that related outage and/or degradation. 
  

	7.1.5.	Planned Service Interruptions by AT&T 

AT&T will provide Motricity with advance notice (via email to ***) of all planned maintenance activities requiring support from
Motricity. AT&T will make every effort to provide *** advance notice and will provide at a minimum *** advance notice of such activities. Such planned activities will exclude changes to Motricity software and/or configurations as these would
require additional notice. 
  

	7.1.6.	Unplanned Service Interruptions by AT&T 

AT&T will notify Motricity of any unplanned service interruptions via email to Motricity Carrier Care (***) as quickly as is reasonably
possible for AT&T. 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 63 

 Motricity will make all reasonable efforts to support AT&T in resolving the issue. Motricity may charge
its standard professional services fees for such efforts. 
  

	7.1.7.	Splash Page During Maintenance 

 The
parties will cooperate to display a “splash page” during any planned or emergency maintenance that would otherwise result in a TCP timeout from a WAP Gateway and other mutually agreed required maintenance activities requiring customer
requests to be blocked whenever reasonably technically feasible. Such a page will be presented to users of both the wired and wireless web access points, to inform them of temporary unavailability of the Services. Service of the splash page does not
constitute availability, but is categorized as either planned or unscheduled service interruption (in accordance with Section 7.1). AT&T will provide the static WML/xHTML content to be displayed in the “splash page”.

  

	7.2.	Capacity Planning Forecasts 

 To ensure
the highest level of service, Motricity requires AT&T at least twice per year to provide a forecast estimating the growth of their customer base (3, 6, 9 and 12 months into the future) and likely service usage. This will allow Motricity to plan
the required resources to support the services for AT&T’s customers. If AT&T becomes aware of any material changes that would impact any forecast previously provided to Motricity (e.g., if AT&T has a special promotion plan in which
a high number of new customers are anticipated), Motricity must be given 30 days advance notice of any change in the forecast to prepare for such additional capacity. If AT&T fails to provide Motricity with such notice, Motricity will not be
held responsible for any failures to the performance objectives that could have been avoided had Motricity received such notice. A forecast provided pursuant to this section is only a forecast and is not a commitment on behalf of AT&T for the
forecasted amount. 
  

	8.	Financial Consequences of Non-Performance 

  

	8.1.	Financial Consequences for Failure to Meet Service Objectives 

The following sections define financial penalties for non-performance related to service objectives within the Motricity Span of Control. 

These non-performance penalties set forth in this Section 8 will apply commencing on the date of commercial launch of the Services, unless the
parties agree in writing to delay the application of non-performance of penalties for a particular Service or Services. The total financial penalties owed to AT&T under the Agreement will be subject to the SLA penalty cap set forth in Table 7 of
Exhibit G-1. For purposes of clarity the SLA penalty cap under this Exhibit G-2 is not in addition to any other SLA exhibit. 
 For any WEB
Services that do not meet the monthly Service objectives set forth within this SLA, Motricity will calculate the aggregate WEB Application User Ratio for the affected WEB Applications to determine the SLA penalty cap to be applied for the month in
which the Service objectives were not met. 
  

 64 

					
	 WEB Application User Ratio
	  	 SLA Penalty Cap
	  	 Illustrative Example

using *** Total

Revenue

	 ***
	  	***	  	***
	 ***
	  	***	  	***
	 ***
	  	***	  	***
	 ***
	  	***	  	***
	 ***
	  	***	  	***

 Table 7, SLA Penalty Cap

 For the purposes of the SLA, “Total Revenue” shall be calculated as follows: the sum of the *** For further detail regarding the
non-performance penalties described below, reference SLA Penalty Calculation Model (Appendix E) below. 
 For any month for which there
is an Availability and a Latency penalty due for the same period of time, Motricity shall be required to pay only the Availability penalty and the Latency penalty shall be waived when mutually agreed that there was a common or related cause.

 Motricity will deduct penalties for non-performance from the subsequent month’s invoice to AT&T for the Services. 

 

	8.2.	Service Availability 

  

	(b)	Service availability targets apply to Services provided to AT&T as described in the SLA Monitoring Requirements (Appendix D) below and will be reported as
required in Section 6 above. [    ]: 

  

							
	 Service Area
	 	 	 	 ***
	  	 
	***	 		 	***	  	
	***	 		 	***	  	
	***	 		 	***	  	
	***	 		 	***	  	

 Table 8, Service Availability Penalty Calculation 

 

	(c)	Subject to Section 8.1, Motricity agrees to pay to AT&T service availability failure fees computed on a monthly basis, as a calculation of (i) plus (ii):

 *** 
 Motricity will
utilize the most recent and relevant historical user data available for the purpose of determining the percentage of users impacted during periods of unavailability. 
  

	8.3.	Service Latency 

 Service latency targets
apply to Services provided to AT&T as described in Appendix D and will be reported as required in Section 6 above. Notwithstanding the foregoing, non-performance penalties will apply solely to the following portions of the
Services as further described in Appendix D: 
  

					
	 	  	 ***
	  	 

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 65 

 Table 9, Latency Penalty Calculation 

Subject to Section 8.1, Motricity agrees to pay to AT&T excessive latency fees based on performance according to Table 9 above for
each month of the SLA reporting period. In the event the monthly latency measurement for a particular Service Area listed in Table 2 above *** 
  

	8.4	*** 

  

	8.5	*** 

  

	9.	Right to Terminate 

  

	(a)	Right to Terminate for Failure to Meet Monthly Service Availability Requirement. 

In the event that the monthly service availability target described in Section 3.1 is not met for the Service Areas listed in
Section 8.2 above in any three calendar months within any four month period during the Term, then, at the end of any such third failed month, AT&T shall have the right, in its sole discretion, to terminate the Agreement for cause upon
thirty (30) days prior written notice to Motricity or to provide Motricity notice of AT&T’s intent to develop a “Get Well Plan.” In the event that AT&T delivers a “Get Well Plan” notice, the parties will use
good faith efforts to agree to and execute on a plan for Motricity to remedy the applicable performance failures and meet the service availability target set forth in Section 3.1. Upon implementation of any such mutually agreed plan, a new four
month measurement period to determine compliance with the service availability requirement will commence. 
  

	(b)	Right to Terminate for Failure to Meet Latency Requirement. 

In the event that the latency requirement described in Section 3.2 is not met for the Service Areas listed in Section 8.3 above
in any three calendar months within any four month period, then, at the end of any such third failed month, AT&T shall have the right, in its sole discretion, to terminate the Agreement for cause upon thirty (30) days prior written notice
to Motricity or to provide Motricity notice of AT&T’s intent to develop a “Get Well Plan.” In the event that AT&T delivers a “Get Well Plan” notice, the parties will use good faith efforts to agree to and execute on
a plan for Motricity to remedy the applicable performance failures and meet the service latency target set forth in Section 3.2. Upon implementation of any such mutually agreed plan, a new four month measurement period to determine compliance
with the service availability requirement will commence. 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 66 

 Appendix A – Contact & Escalation List 

Both parties are responsible for ensuring that the contact information is updated and exchanged when circumstances warrant. This information will not be
updated and kept current as part of this SLA, but will need to be maintained separately by the two parties outside of this document. 

Motricity Customer Care Contact Information 
  

			
	 Primary Contact (Single Point of Contact) 24 X 7

	Contact Name	  	Service Operations Center (SOC) / Carrier Care
	Title	  	N/A
	Phone	  	***
	Email	  	***
	
	 Level 1 Escalation

	Contact Name	  	***
	Title	  	Manager, Service Operations
	Phone	  	***
	Email	  	***
	
	 Level 2 Escalation

	Contact Name	  	***
	Title	  	Director, Commercial Operations
	Phone	  	***
	Email	  	***

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 67 

			
	 Level 3 Escalation

	Contact Name	  	***
	Title	  	Sr. Director - Systems & Network Operations
	Phone	  	***
	Email	  	***

 AT&T Contact Information 

 

							
	 AT&T
	  	 Hours of Operation
	  	 Role
	  	 Phone/Email

	NSD National
Operations
Center	  	24 x 7 x 365	  	Incident Management and Emergency Maintenance	  	***
				
	MMS External
Partner Ops	  	8:00 am – 5:00 pm
PT Monday – Friday	  	Incident Root Cause Analysis, Change Management, Performance Reports and Tier 2 Support	  	***
				
	Change
Management	  	8:00 am – 5:00 pm
PT Monday – Friday	  	Maintenance Notification
– all maintenance	  	***

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 68 

 Appendix B – Maintenance Request Worksheet 

This Maintenance Request Worksheet is be sent to: *** and *** 

 

	12)	Title of Maintenance 

  

	13)	Brief Description of Maintenance 

  

	 	•	 	 Scope and full description 

  

	 	•	 	 AT&T service 

  

	14)	Maintenance Start Date & Time 

  

	15)	Maintenance End Date & Time 

  

	16)	AT&T Service Impact 

  

	 	•	 	 Impact to AT&T internal & external customers 

 

	 	•	 	 Explanation of Information Service unavailability 

  

	17)	Information Service Impact Assessment (within the scheduled window) 

 

	 	•	 	 Duration in minutes 

  

	 	•	 	 Estimated start/end time of AT&T service impact 

  

	18)	Risk Assessment 

  

	19)	Partner Maintenance Request Number 

  

	20)	Point of Contact 

  

	 	•	 	 Name, telephone numbers 

  

	21)	Maintenance Install Team 

  

	22)	Update Schedule 

  

	 	•	 	 Cancellation of Maintenance – as soon as possible 

 

	 	•	 	 Start of Maintenance Window 

  

	 	•	 	 Notify when Down Time begins 

  

	 	•	 	 Notify when Information Service is restored (Down Time ends) 

 

	 	•	 	 Notify of Problem 

  

	 	•	 	 Maintenance runs outside window 

  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 69 

 Appendix C – Incident Notification 

Incident Notification or Trouble Ticket (send to: ***) 
  

	11)	Title of Incident 

  

	12)	Brief Description of Incident 

  

	 	•	 	 Should include scope (AT&T service impacted) 

  

	13)	Start Date and Time 

  

	14)	Information Service Resolution Date and Time 

  

	15)	Duration of Outage 

  

	 	•	 	 Provided at time of restoration 

  

	16)	AT&T Information Service Impact 

  

	 	•	 	 Impact to AT&T End Customer 

  

	17)	Partner Ticket Number 

  

	18)	Partner Severity Level 

  

	 	•	 	 Based on quantified Information Service impact 

  

	19)	Technical Action Take to Correct Incident 

  

	 	•	 	 Steps taken to restore Information Service 

  

	20)	Initial Root Cause 

  

	 	•	 	 Suspect root cause (brief) 

  

	 	•	 	 Formal RCA for SIR 1 or chronic issues of lower severity 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 70 

 Appendix D – SLA Monitoring Requirements 

*** 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 71 

 Appendix E – My Media Net SLA Penalty Calculation 

*** 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 75 

 EXHIBIT I - WORK REQUEST PROCESS 

Work Request Control Process 
  

 
 by and between

 AT&T and Motricity 
  

 
 October 2008

 Prepared by AT&T 
  

	1.	Introduction 

 AT&T and Motricity are
implementing a work request control process that is fast and efficient to update /modify existing Services solely for those items listed below (“Work”): 
  

	 	•	 	 The purchase and/or installation of hardware (and related software) that Motricity purchase on behalf of AT&T in providing its Services to
AT&T; 

  

	 	•	 	 Ad-hoc maintenance; and 

  

	 	•	 	 The creation of reports. 

  

 76 

 The goal of the process is to provide the opportunity for teams to submit Work Requests to
and to ensure such Work proposals are given the appropriate amount of analysis and review to ensure there are no impacts to current Services, costs and timeframes are mutually agreed upon. Lastly, the process will allow AT&T and Motricity to
both approve any and all Work Requests. 
  

	2.	Scope of the Work Request Process 

  

	 	a.	The work request process will be used to manage Work Requests and to approve changes that may impact either the scope, schedule, or cost of existing projects or
Services for authorized Work. 

  

	 	b.	Custom Development 

 Any custom
development, professional services or requests for new Services that involve determination of work efforts are to be handled under the Services Agreement. 
  

			
	 Project/Work Proposal
	 	 Work Control Effective Date

		 	
		 	
		 	
		 	
		 	
		 	

  

	3.	Work Request Process 

  

	 	a.	AT&T Submits a Work Request 

 An
AT&T team member identifies the need to update, change or modify an existing Service for Work contemplated under the Agreement. The team member fills out a Work Request form and submits it to the AT&T Project Manager (“PM”), or
his/her designee. Based on the AT&T PMs’ assessment of the importance of the request, and his/her authorization level to approve the Work Request, the AT&T PM will seek additional approval from AT&T’s upper management (Director
level or higher) as appropriate and consistent with the AT&T schedule of authorization. 
 Once approved by the AT&T PM, the Work
Request is sent to the Motricity PM. Within no more than three business days, Motricity will assess the feasibility of the Work Request in terms of technical risk, cost, and schedule impacts. Once the assessment is complete, Motricity will respond
back to AT&T with an approval, disapproval or request for clarification. Any disapproval of Work Requests will need to be explained within the Work Request Form to be returned to AT&T’s PM. 

Upon receipt of an approved Work Request Form from Motricity, AT&T’s PM will obtain any further internal approvals from AT&T’s upper
management the Work Request will be signed and become effective immediately upon the execution of a Work Order by AT&T and Motricity. 
  

	 	b.	Motricity Submits a Work Request 

 A
Motricity team member identifies the need to update, change or modify an existing Service for Work contemplated under the Agreement. The team member fills out a Work Request form and submits it to the Motricity Project Manager (“PM”), or
his/her designee. Based on the Motricity PMs’ assessment of the importance of the request, and his/her authorization level to approve the Work Request, the Motricity PM will seek additional approval from Motricity upper management (Director
level or higher) as appropriate and consistent with the Motricity schedule of authorization. 
  

 77 

 Once approved by the Motricity PM, the Work Request is sent to the AT&T PM. Within no more than three
business days, AT&T will assess the feasibility of the Work Request in terms of technical risk, cost, and schedule impacts. Once the assessment is complete, AT&T will respond back to Motricity with an approval, disapproval or request for
clarification. Any disapproval of Work Requests will need to be explained within the Work Request Form to be returned to Motricity’s PM. 

Upon receipt of an approved Work Request Form from AT&T, Motricity’s PM will obtain any further internal approvals from Motricity’s upper
management, the Work Request and will be signed and become effective immediately upon the execution of a Work Order by AT&T and Motricity. 
  

	4.	Acceptance Process 

 AT&T shall have
the right to review Services and/or Products to determine whether the Services and/or Products conform to the requirements set forth in the respective Work Order and to either: (i) reject the Services/Products if it fails to conform to the
requirements set forth in the respective Work Order or (ii) to provide its Acceptance (in whole or in part) if there are no Service Defects. If AT&T rejects the Services and/or Products, Motricity shall, at AT&T’s request, promptly
correct all such Service Defects and, thereafter, AT&T shall again have the opportunity to review the Service and/or Products. If Motricity is not able to correct all Service Defects in the Services and/or Products within thirty (30) days
following receipt of AT&T rejection, AT&T shall have the right to terminate the affected Work Order, in whole or in part, which termination shall be deemed due to Motricity’s default. In the event of any such termination, Motricity
shall return all payments previously made to Motricity under this Agreement for the affected Work Order and AT&T shall not be subject to any cancellation charges. 

 

 78 

 EXHIBIT I - WORK REQUEST FORM 

Work Request Form 
  

			
	AT&T Requestor:	 	Work Control #:
	Work Request Name:	 	Date Received:
	Work Request Priority: High/Med/Low	 	

 <<Insert Work Request Name and/or Number>> 

 

	1	Work Request Information 

A. Description of Work Request to include any requirements 

<<Note: any customized development being done on behalf of AT&T must be done under the Services Agreement.>> 

Requirements to be attached to this Work Request: 

General requirements 
 HTML Portal requirements

 WML Portal requirements 
 SMS
requirements 
 Admin Tool(s) requirements 
  

	 	B.	Reason for the Work Request and Impact if not implemented 

  

 

	 	C.	Motricity and AT&T Agreements governing this Work Request 

  

Wireless Service Agreement No. 00014249 
  

 79 

	2	Impact Analysis 

  

	 	A.	Impact Assessment (Include what use cases, system components or operations areas are impacted) 

 
  

	 	B.	Cost Impact 

  

 

	 	C.	Payment Schedule 

  

 

	 	D.	Schedule Impact (What tasks and milestones are impacted?) 

  

 

	 	E.	Resource Impact (Will more resources need to be added to the project? If yes, provide details below.) 

 
  

	 	F.	Impact Classification (High / Medium / Low):  

  

	3.	Work Request Review 

  

	 	A.	Date Reviewed 

 Reviewers

  

			
	 Name
	  	Project Role
		  	
		  	
		  	

 Final Recommendation 
  

 80 

	4.	Work Request Decision 

Approved for the work identified above in support of the Agreement             
(Y/N): 
 Signatures: 
  

							
	 Name
	  	Title	  	Signature	  	Date
		  		  		  	
		  		  		  	
		  		  		  	
		  		  		  	

  

	5.	Work Request Disposition 

 This
Section to be completed by the Motricity Project Manager 
  

4. Work Request Decision 

Approved for the work identified above in support of the Agreement
             (Y/N): 
 Signatures: 

 

							
	 Name
	  	Title	  	Signature	  	Date
		  		  		  	
		  		  		  	
		  		  		  	
		  		  		  	

 5. Work Request Disposition 

This section is to be filled in only by the Motricity Project Manager 

 

 81 

 EXHIBIT J 

WORK ORDER 

Work Order No.              

to Second Amended and Restated Wireless Services Agreement #00014249 

Motricity, Inc. (“Motricity”) will perform the Work identified below for AT&T Mobility LLC (“AT&T”), under the terms and
conditions of that certain Second Amended and Restated Wireless Services Agreement #00014249, dated July 22, 2005 between Motricity and AT&T (as amended, the “Agreement”). In consideration of Work below, Company will pay to
Motricity the amount(s) set forth below, upon Acceptance, pursuant to Section 5 of the Agreement. 
  

			
	 Work Request Name/Numbers
	  	 Estimated Completion Date

	 Work Request No.
                    
  

and/or
  

See attached Work Request Form(s).
	  	Motricity will use commercially reasonable efforts to complete the Work by ___________.

 

			
	 Amount
	  	 Due Date

	 $            
	  	Forty-five (45) days from receipt of valid invoice..

 This
Work Order is made under and incorporates the terms and conditions of the Agreement. The terms and conditions set forth in this Work Order are in addition to and not in substitution of any terms or conditions set forth in the Agreement. Except as
specifically modified by this Work Order, the terms and conditions of the Agreement remain in full force and effect. 
  

					
	Motricity, Inc.	 		 	AT&T Mobility LLC
			
	  	 		 	  
	Authorized Signature	 		 	Authorized Signature
			
	  	 		 	  
	Printed Name and Title	 		 	Printed Name and Title
			
	  	 		 	  
	Date	 		 	Date

  

 82 

 EXHIBIT M 

SECURITY REQUIREMENTS 

*** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 83 

 AT&T PRIVACY POLICY 

(Effective date: October 21, 2006) 

AT&T has a long-standing policy of protecting customer privacy. 

We believe that you should know what information we collect from you, as well as how that information is used, disclosed, and protected. We have created
this policy statement (the “Policy”) to explain our privacy practices and policies. 
 We will not sell or disclose your personal
information to unaffiliated third parties without your consent except as otherwise provided in this Policy. We may use information about who you are, where and when you browse on the Web, where your wireless device is located, and how you use our
network to provide you better service and enrich your user experience when you sign up or use any of our products or services. 
 AT&T may
make available shorter or machine-readable versions of this Privacy Policy. These additional policies are intended only as summaries of this complete Privacy Policy. This Policy applies to customers who purchase and use our services and products in
the United States. Collection, use, disclosure, and protection of personal information may be subject to different regulation outside the United States. 

AT&T will revise and update this Policy as it deems appropriate, including, for example, if our practices change or if changes in the law so require.
You should refer back to this page for the latest information. 
 QUICK PRIVACY LINKS 

The following brief summaries outline our Policy and then link to further detail. We also provide you the means to communicate with us if you have any
questions about this Policy. This Policy also addresses what we do with information about your device usage, the services you buy from us, and who you call. 

Does AT&T Collect Personal Information About Me? 

Yes, AT&T collects personal information about you so that we can deliver products or services you request. 

 

 86 

 This happens automatically when you interact with us, such as when you log into a service. Sometimes,
AT&T buys commercially available marketing and sales information from third parties so we can better serve you. 
 Does AT&T Collect
Information About Children Under the Age of 13? 
 If we make available offers and products online where a child informs us that he or she is
under the age of 13, we will ask a parent to confirm his/her consent in advance of further collection, use or disclosure of personal information from that child. 

How Does AT&T Use Personal Information? 

We use personal information for billing and collection purposes, to provide services or complete transactions you have requested, and to anticipate and
resolve problems with your services. We may also use this information to create and inform you of products or services from AT&T or others that may better meet your needs. 

When Does AT&T Disclose Personal Information? 

We do not sell personal information to unaffiliated third parties. We will disclose personal information to third parties to complete a transaction you
have requested, as part of the terms and conditions for a particular service, to collect on an account, or when we otherwise have your consent to do so. We also may disclose personal information to third parties to protect the rights and property of
the company or its subscribers. 
 What Happens to Information About My Telephone Usage and Who I Call? 

Under federal law, you have a right, and we have a duty, to protect the confidentiality of information about your device usage, the services you buy from
us, who you call, and the location of your device on our network when you make a voice call. 
  

 87 

 Does AT&T Use Cookies? 

Yes. AT&T uses cookies for a variety of reasons, including improving your shopping or browsing experience. In addition, cookies help us personalize
the site experience for you. 
 Does AT&T Use Web Beacons? 

Yes. AT&T uses Web beacons, also known as Web bugs, on our sites so that we can identify you and deliver you the services you request. However,
AT&T does not permit third parties to use Web beacons linked to personal information on our site. 
 Does AT&T Place Advertising on
Other Web Sites? 
 AT&T currently uses third-party advertising companies to place our ads on the Internet, and cookie and Web beacon
technologies are used to measure the effectiveness of those ads. You should know that the use of such cookies is subject to the third parties’ privacy policies, and not the policy of AT&T. 

What About Presence, Location, and Tracking Information? 

Our network knows the general location of your phone whenever it is turned on. When we offer you optional services that require use or disclosure of this
information, the terms and conditions for the specific service offering explain how the location information will be used. We also may provide your network location to emergency service providers if you place a 911 call. 

 

 88 

 Can I Choose Not to Receive Marketing Messages on My Wireless Device from Third Parties? 

AT&T has implemented technology to reduce unsolicited bulk short text messages but is unable to filter all marketing messages that you receive on your
wireless device from third parties. 
 How Secure Is Information About Me? 

We maintain a variety of physical, electronic, and procedural safeguards to guard your personal information. 

What Can I Do to Protect My Personal Information? 

An important part of ensuring the security of your personal information is your own efforts to protect against unauthorized access to your wireless device
and SIM card. Before discarding your device or trading it in, be sure you remove all your personal information from the device. 
 How can I
Review Personal Information in my Account for Accuracy? 
 You can review the accuracy of the personal information in your account online (go
to My Account on this Web site) or by contacting Customer Service at 1-800-331-0500. 
 Will This Policy Be Updated? 

AT&T expects to update this Policy periodically. You should refer back to this page often for the latest information and the effective date of any
changes to the Policy. 
 To Whom Should I Direct Privacy Questions or Concerns? 

You have several ways to contact us about questions of this Policy and about your services. 

 

 89 

 AT&T PRIVACY POLICY 

We have created the AT&T Privacy Policy (the “Policy”) to explain our privacy practices. When you use any AT&T product or service, you
should understand when and how personal information is collected, used, disclosed and protected. 
 We will not sell or disclose information to
unaffiliated third parties without your consent except as otherwise provided in this Policy. We may use information about who you are, where and when you browse on the Web, where your wireless device is located, and how you use our network to
provide you better service and enrich your user experience when you sign up or use any of our products or services. 
 AT&T will revise and
update this Policy if our practices change or if changes in the law so require. 
 Information Collected About You 

We collect a variety of personal information about users of our products or services. Personal information is information that can be directly associated
with a specific person or entity, such as a name, address, telephone number, email address, or information about activities directly linked to that person. 

Our definition of personal information does not include “aggregate” information. Aggregate information is data we collect about a group or
category of services or customers from which individual customer identities have been removed. For example, we could prepare a report that indicates that a certain number of our customers always use their wireless phones at a certain time of day at
a specific location. Aggregate data helps us understand trends and customer needs so that we can better consider new services or tailor existing services to customer desires. The aggregate data also might be purchased by or shared with a third
party, for example, one interested in locating a business in a particular part of town. 
 Here are the types of personal and other information
we collect. You should refer to the rest of this Policy to see how we use, disclose, and protect that information: 
  

	 	•	 	 Information You Give Us 

  

 90 

 We collect information you give us when you purchase a AT&T product or use services. For
example, you may provide us a billing address and credit information, including your social security number or business identifier, when signing up for service or perhaps purchasing a product through our online store. You might not have thought
about it this way, but the numbers dialed from your wireless phone to make a call are an example of information you give us and that we collect and use so we can bill you appropriately and investigate fraudulent usage. 

 

	 	•	 	 Automatically Collected Information 

We automatically receive certain types of information whenever you interact with us. For example, when you visit an AT&T Web site, our
systems automatically collect your IP address and the type of browser you use. When you browse the wireless web, our systems log the Web sites you visit. Similarly, all wireless communications systems know when your phone is turned on and
approximately where the device is physically located—that’s how calls or messages are delivered to you in real time. 
  

	 	•	 	 Information from Other Sources 

We may obtain information about you from outside sources and add it to or combine it with your account information. For example, we may
receive credit information for purposes of initiating service. We also may use commercially available demographic and marketing information from third parties to help us better serve you or inform you about products or services that we think will be
of interest to you. We sometimes receive updated delivery and address information from our shippers or other sources so that we can correct our records and deliver your next purchase or communication more easily. And, we often receive information
from the dealer from whom you purchase your wireless phone or device prior to initiating service with us. 
 We also may purchase email lists
from third parties for advertising purposes. We only purchase lists of individuals who have allowed third-party use of their email address for marketing purposes. If you have previously requested to participate in an email advertising program, the
information we receive may include your name, information on previous transactions, or any other personal information you have provided. 

AT&T recognizes that parents often purchase our products and services for family use, including for use by minors. Any information collected from
such usage will appear to be the personal information of the actual subscriber to the service, and will be treated as such under this Policy. If we make available offers and products online where a child informs us that he or she is under the age of
13, we will ask a parent to confirm his/her consent in advance of further collection, use or disclosure of personal information from that child. 
  

 91 

 In a Business Agreement, our customer is a business or other entity purchasing service for employees or
other authorized users. If you receive certain benefits through a business or government customer’s agreement with us, this Policy will generally govern your personal information. However, if you receive service where a business or government
entity pays AT&T for your account or is otherwise liable to AT&T for the charges (for example, as a guarantor if you fail to pay), we may share your account information with that entity. If you receive certain benefits tied to a Business
Agreement, but you are liable for your own charges, then we may share enough account information with that entity to verify your continuing eligibility for those benefits. Please contact AT&T if you have any questions about who is the liable
party on your bill. 
 Children’s Online Privacy Protection Act 

If we make available offers and products online where a child informs us that he or she is under the age of 13, we will ask a parent to confirm his/her
consent in advance of further collection, use or disclosure of personal information from that child. You should be aware, however, that wireless devices and services purchased for family use may be used by minors without the knowledge of AT&T.
If that happens, any information collected from the usage will appear to be the personal information of the actual adult subscriber and treated as such under this Policy. 

Use of Personal Information 
  

	 	•	 	 Internal Use. 

In general, we use personal information to serve our customers, to enhance and extend our customer relationship, and to enable our
customers to take maximum advantage of products and services we think they would enjoy. For example, by understanding how you use our Web site, we are able to customize and personalize your experience. More specifically, we use personal information
for billing purposes, to provide services or complete transactions you have requested, to anticipate and resolve problems with your services, and to create and inform you of products or services from AT&T or others that better meet your needs.

 AT&T uses email, short text messages, telemarketing, and direct mail to inform you about products or services we think
will interest you. You can modify your preferences on receiving these types of communications: 
  

	 	•	 	 If you are currently a AT&T customer and wish to change your preferences on receiving these types of communications, you can do one of the
following to tell us your preferences: 

  

	 	•	 	 Complete an online form 

  

 92 

	 	•	 	 Visit the “My Profile” page, if you manage your account online. 

 

	 	•	 	 Call Customer Service at 1-800-331-0500. 

  

	 	•	 	 If you are not a current customer of AT&T and wish to opt out of receiving marketing communications, you can complete an online form to tell us
your preferences. 

 While you may choose not to receive marketing information from us, you will continue to
receive invoices, customer service-related notifications, and other similar information from us electronically or otherwise. 
  

	 	•	 	 Third-Party Use. 

You should review the following section to understand when AT&T discloses personal information to third parties. 

Disclosure of Personal Information 

Information about our customers is one of our most important business assets, and therefore we strive to protect it and keep it confidential. We do not
sell personal information to third parties without your consent. When and what types of information AT&T discloses depends on the service and in some cases the choices you have made. 

AT&T will not disclose personal information other than in accordance with this Policy. In general, that means that you must consent to the disclosure
in advance. Depending on the service, we may obtain your consent in a number of ways, including: 
  

	 	•	 	 In writing; 

  

	 	•	 	 Verbally; 

  

	 	•	 	 Online by clicking a button; 

  

	 	•	 	 Through the use of a dialing string or button on a wireless device or handset; or 

 

	 	•	 	 At the time of initiation of a particular service offering, when your consent is part of the required terms and conditions to use that service.

  

 93 

 For example, your consent to disclose personal information can be implied simply by the nature of your
request, such as when you ask us to deliver an email or short message to another person. Your return address is disclosed as part of the service and your consent to do so is implied by your use of the service. To determine how personal information
may be disclosed as part of a particular service, you should review the terms and conditions of use for that service. 
 We share personal
information with third parties as necessary to complete a transaction, perform a service on our behalf (such as enhancing our ability to serve you better), or perform a service that you have requested. When the third party acts solely on our behalf,
AT&T does not allow them to use your information for other purposes. For example, our vendors process and print your billing statement on our behalf. They can only use the personal information we give them to produce the billing statement. When
we write off an account for non-payment, AT&T sometimes discloses personal information about the account to third parties such as credit bureaus. Credit bureaus may use the personal information to update their records. AT&T does not
currently disclose wireless numbers in AT&T listings or published directories. If we do so in the future, you will be able to choose whether your number is listed. 

Aside from our services, however, you may also want to take advantage of services and products offered by other companies utilizing our wireless service.
In those cases, you will be providing information to those companies, and information about you received by those third parties will be governed by their privacy policies, not this Policy. For example, if you are roaming on the network of another
carrier, information about your usage and the numbers you dial will be available to the carrier providing the service. Also, as another example, if you purchase something using our mobile Internet service, you will be disclosing personal information
directly to the company facilitating the transaction, a merchant bank and the merchant. Finally, if you bought your wireless device from a third party retailer or dealer, both they and AT&T will have personal information as a result of the
transaction and your ongoing service with AT&T. Whenever third parties have a role in any such transaction, you should review their privacy policies as well. 

From time to time you may be able to participate in contests, giveaways, or other similar promotions we sponsor. Except as explained otherwise in the
rules for a particular contest, giveaway, or promotion, any personal information you provide will be used in accordance with this Policy. 
 In
addition, from time to time you may be able to participate in our surveys to help us improve our offerings and services. Except as explained otherwise in the survey, any personal information so collected will be used for our internal purposes.

  

 94 

 Under federal law, you have a right, and we have a duty, to protect the confidentiality of information about
your telephone usage, the services you buy from us, who you call, and the location of your device on our network when you make a voice call. This information is sometimes referred to as “Customer Proprietary Network Information,” or
“CPNI.” We share CPNI and other personal information about you with affiliates of AT&T and BellSouth Corporation (the parent companies of AT&T) that provide telecommunications services to which you also subscribe. Before sharing
CPNI in any other way, we will first notify you of your rights under the law, describe how we intend to use the CPNI, and give you an opportunity to opt out of such usage (or, when required by law, to opt in). 

Business Transfers: 
 Information about
our users, including personal information, may be disclosed as part of any merger, acquisition, sale of company assets, or transition of service to another provider, as well as in the unlikely event of an insolvency, bankruptcy, or receivership in
which personal information would be transferred as one of the business assets of the company. 
 Protection of AT&T and Others:

 We release personal information when we believe release is appropriate to comply with the law or in good faith reliance on legal process
(e.g., court orders, subpoenas, E911 information, etc.); enforce or apply our customer agreements; initiate, render, bill, and collect for services; protect our rights or property, or protect users of those services and other carriers from
fraudulent, abusive, or unlawful use of, or subscription to, such services; facilitate or verify the appropriate calculation of taxes, fees, or other obligations due to a local, state, or federal government; or if we reasonably believe that an
emergency involving immediate danger of death or serious physical injury to any person requires disclosure of communications, or justifies disclosure of records, to a governmental entity without delay. 

AT&T Use of Cookies 
 Cookies are
small files placed on your computer’s hard drive by a Web site when you visit. These files identify your computer and record your preferences and other data about your visit so that when you return to the site, the site knows who you are and
can personalize your visit. For example, cookies enable a Web site shopping cart to function so that you only have to check out once. Consequently, cookies are often tied to the use of personally identifiable information while using our site, and
some functionality may be lost if you choose not to accept the use of cookies. 
  

 95 

 In general, we use cookies to collect information so that we can determine how to improve our site by seeing
which areas, features and products are most popular; to personalize the site and make recommendations based on products you have liked in the past as well as to improve the site experience; and to complete transactions you have requested.
Advertisers that serve ads on our site may also use their own cookies. Such outside cookies are governed by the privacy policies of the entities placing the ads, and are not subject to this Policy. 

We also use a session-based cookie that maintains a user’s session for continuity of navigation while viewing the site. After closing the browser
the session cookie simply terminates. 
 With wireless Internet service, cookies are also used by our suppliers and third-party vendors to
facilitate the various services and information offered. Depending on the phone or device being used, cookies may be stored locally on the phone or device, or on servers operated by AT&T. This Internet cookie-like functionality is in place for
the same reasons and designed for the same purposes as cookies placed on your computer when interacting with Internet Web sites. Our suppliers and vendors will only use this information to provision the service, but each site you visit while using
the wireless Internet service is controlled by a separate company and their individual privacy policies will govern information they receive automatically from the cookie or information you voluntarily provide. 

AT&T Use of Web Beacons 
 A Web
beacon, also known as a Web bug, is a small, graphic image on a Web page, Web-based document or in an email message that is designed to allow the site owner or a third party to monitor the address and other information of the computer viewing the
item. Web beacons are often invisible to the user because they are typically very small (only 1-by-1 pixel) and the same color as the background of the Web page, document, or email message. Web beacons are represented as HTML IMG tags in the Web
page; users can click on “view profiles” of the Web page to see whether the page is using a Web beacon. Web beacons collect the IP address of the computer that the Web beacon is sent to, the URL of the page the Web beacon comes from, and
the time it was viewed. Web beacons can also be linked to personal information. 
 AT&T does not place Web beacons that link to personal
information on other sites, nor does it permit third parties, other than those working on our behalf, to place them on our site. AT&T does use Web beacons itself and may link a particular beacon to personal information. For example, we may use a
beacon to ensure a user can flip between technical assistance, customer service and our online store and still be recognized as our customer. 
  

 96 

 AT&T Placement of Advertising on Other Web Sites 

AT&T may use third-party ad serving companies to place advertisements about our products and services on other Web sites. These companies may use
cookies and other technology such as Web beacons or tagging to measure the effectiveness of our ads. To measure advertising effectiveness and offer selective ad content, the ad serving companies may use anonymous information about your visits to our
and other Web sites. But the ad serving companies use an anonymous number to identify you, NOT your name, address, phone number, email address, or anything that personally identifies you. The use of such cookies is subject to the ad serving
company’s privacy policy, not the Policy of AT&T. If you would like more information about these companies we use, their privacy practices, or to learn your choices about not having this non-personal information used to serve ads to you,
see our AT&T Ad Serving Companies. 
 AT&T Advertising Companies 

This list contains a link to the privacy policies for the ad-serving companies used to place ads on 3rd party sites. AT&T will revise or update this
as we change existing or add new ad-serving companies. 
  

	 	•	 	 Avenue A and Atlas 

Presence, Location, and Tracking 
 To
make wireless communications possible, the network knows the general location of your phone or wireless device whenever it is turned on. Your wireless device sends out a periodic signal to the nearest radio tower/cell site so that the network will
know where to route an incoming communication and how to properly bill for the service. This is necessary to make wireless communications possible. 
  

 97 

 If you dial 911 for emergency services, we may provide your network location to a public safety answering
point, emergency medical service provider or emergency dispatch provider, public safety, fire service, or law enforcement official, or hospital emergency or trauma care facility. The law also permits us to disclose the location of a device on our
network without a user’s consent (1) to a user’s legal guardian or members of a user’s immediate family in an emergency situation that involves the risk of death or serious physical harm, (2) to database management services
or information providers solely to assist in delivering emergency services, or (3) to a governmental entity if we reasonably believe that an emergency involving immediate danger of death or serious physical injury to any person requires or
justifies disclosure of a device’s location on the network without delay. Legally required upgrades will allow us to provide a location more precise than cell site location. 

In addition, we offer optional services on our GSM/GPRS network that make use of your network location. Please review the terms and conditions for each
service for additional information about how the location information will be used. The location used for these services is separate from the network location information when you make a voice call. 

Your wireless Internet service may also be personalized using your ZIP code or other location identifiers. We use this information to serve you relevant
content, and we treat the information like any other personal information under this Policy. This service does not use the network location technology described in this section. 

Receipt of Marketing Messages on My Wireless Device from Third Parties 

You should be aware that not all advertisements appearing on or delivered to your mobile phone or device are authorized by AT&T. We have developed and
implemented systems in our network to reduce unsolicited bulk short text messages, but we cannot at this time block all such messages. We continue to look for other options to reduce these unsolicited bulk messages. If you have an email account with
AT&T, this service is subject to unsolicited messages as any other email service. 
 It is unlawful for any third party to make an
unsolicited telemarketing call using an autodialer or to send a prerecorded message to a wireless phone or device. You should report any such unsolicited calls to the Federal Communications Commission. 

 

 98 

 Network and Information Security 

We maintain a variety of physical, electronic, and procedural safeguards to guard your personal information. For example, we use accepted tools and
techniques to protect against unauthorized access to our systems. Also, we grant access to personal information about you to employees and contractors who need to know that information to provide products or services to you. In addition, we work to
protect the security of your personal information when you are ordering new service via the AT&T Web site by using well-known Internet encryption technologies like Secure Sockets Layer (SSL). We also use encryption technologies to protect your
account information when you are viewing your bill on our Web site. You should be aware that AT&T has no control over the security of other sites on the Internet you might visit, interact with, or from which you buy products or services.

 What Can I Do to Protect My Personal Information? 

An important part of ensuring the security of personal information is your own effort to protect against unauthorized access to your wireless device and
the personal information contained in it and on your SIM card. Most phones and wireless PDA-type devices store calling information both in the phone and on the SIM card. Therefore, before discarding your phone or PDA, trading it in or giving it
away, be sure you remove and retain your SIM card and follow the manufacturer’s instructions for deleting all personal information on the device itself. (This can be found in your owner’s manual or on the manufacturers’ Web site.)

 In addition, use passwords to prevent unauthorized access to your wireless device, your wireless service account, and your voicemail. If you
write down your passwords or user names, keep the information in a secure location. Do not give your password to someone else unless you intend them to have the same full access and ability to make changes to your account as you have. Change your
passwords periodically. 
 Accuracy of Personal Information in Your Account 

You can review the accuracy of the personal information in your account records online (go to My Account on this Web site) or by contacting Customer
Service at 1-800-331-0500. 
  

 99 

 California customers: AT&T does not disclose customers’ personal information to third
parties for the third parties’ direct marketing purposes, as governed by California Civil Code 1798.83. 
 Updating this Policy 

 AT&T will revise or update this Policy as it deems appropriate, including for example, if our practices change, as we change existing or
add new services, as we develop better ways to inform you of products we think will be of interest, or if the law so requires. You should refer back to this page often for the latest information and the effective date of any changes. 

If, however, users’ personally identifiable information will be used in a manner materially different from that stated at the time of collection, we
will notify users via posting on this page for 30 days before the material change is made. Users will have a choice as to whether or not their information will be used in this materially different manner. 

Contact Us 
 AT&T is committed to the
policies set forth in this Policy. 
 If you have any questions, comments or concerns about this Policy, please contact privacy@att.com.

 If you have questions about your AT&T service, you can call a customer service representative at 1-800-331-0500. 

 

 100 

 APPENDIX G – PRIME SUPPLIER – MBE/WBE/DVBE PARTICIPATION PLAN 

For purposes of this Appendix G, Supplier refers to Motricity. 
  

							
	 PRIME SUPPLIER MBE/WBE/DVBE PARTICIPATION PLAN

				
	 YEAR

REPORTING:
	  		  		  	

  

							
	PRIME SUPPLIER NAME:	  	 Motricity, Inc.

	ADDRESS:	  	 	  	 	  	 
		  	 	  	 	  	 
	COMPANY E-MAIL:	  	 	  	 	  	 
	TELEPHONE NUMBER:	  	 	  	 	  	 

  

							
	DESCRIBE GOODS OR SERVICES BEING PROVIDED UNDER THIS AGREEMENT:
	
	DESCRIBE YOUR M/WBE-DVBE OR SUPPLIER DIVERSITY PROGRAM AND THE PERSONNEL DEDICATED TO THAT PROGRAM
	
	THE FOLLOWING, TOGETHER WITH ANY ATTACHMENTS IS SUBMITTED AS AN MBE/WBE/DVBE PARTICIPATION PLAN.
	
	1. GOALS
	A. WHAT ARE YOUR MBE/WBE/DVBE PARTICIPATION GOALS?

  

							
			
	MINORITY BUSINESS ENTERPRISES (MBEs)	  		  	***    
			
	WOMAN BUSINESS ENTERPRISES (WBEs)	  		  	***    
			
	DISABLED VETERAN BUSINESS ENTERPRISES (DVBEs)	  		  	***    
		
	 B. WHAT IS THE ESTIMATED ANNUAL VALUE OF THIS CONTRACT WITH:
	  	
		
	Midwest Region:	  	
			
	 (Wisconsin, Illinois, Indiana, Ohio,

Michigan)
	  	 	  	

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 101 

			
		
	AT&T (NV)	  	 
		
	AT&T (CA)	  	 
		
	East Region: (Connecticut)	  	 
	Southwest Region:	  	 
	(Texas, Oklahoma, Kansas, Missouri, Arkansas)	  	 
	AT&T Yellow Pages	  	 
	AT&T Advanced Solutions	  	 
	AT&T National Data Operations	  	 
	AT&T Long Distance	  	 
	AT&T Telecom	  	 
	AT&T Internet Services	  	 
	AT&T MSI	  	 
	AT&T Services	  	 
	AT&T Operations	  	 
	AT&T Mobillity LLC	  	 ***

	Other	  	 

  

							
	Note: Indicate dollar award(s) as it applies to this contract.
	
	C. WHAT ARE THE DOLLAR AMOUNTS OF YOUR PROJECTED MBE/WBE/DVBE PURCHASES:

  

					
	MINORITY BUSINESS ENTERPRISES (MBEs)	  	***
		
	WOMAN BUSINESS ENTERPRISES (WBEs)	  	***
		
	DISABLED VETERAN BUSINESS ENTERPRISES (DVBEs)	  	***

  

							
	 2.
	  	2.	  	LIST THE PRINCIPAL GOODS AND SERVICES TO BE SUBCONTRACTED TO MBE/WBE/DVBEs OR DELIVERED THROUGH MBE/WBE/DVBE VALUE ADDED RESELLERS

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 102 

 DETAILED PLAN FOR USE OF M/WBEs-DVBEs AS SUBCONTRACTORS, 

DISTRIBUTORS, VALUE ADDED RESELLERS 

For every product and service you intend to use, provide the following information. (attach additional sheets if necessary) 

 

									
	 Company Name
	  	Classification
(MBE/WBE/DVBE)	  	Products/Services
to be
provided	  	$ Value	  	Date to Begin
		  		  		  		  	
		  		  		  		  	
		  		  		  		  	
		  		  		  		  	
		  		  		  		  	
		  		  		  		  	
		  		  		  		  	
		  		  		  		  	
		  		  		  		  	
		  		  		  		  	
		  		  		  		  	
		  		  		  		  	
		  		  		  		  	

  

	3.	SELLER AGREES THAT IT WILL MAINTAIN ALL NECESSARY DOCUMENTS AND RECORDS TO SUPPORT ITS EFFORTS TO ACHIEVE ITS MBE/WBE/DVBE PARTICIPATION GOAL(S). SELLER ALSO
ACKNOWLEDGES THE FACT THAT IT IS RESPONSIBLE FOR IDENTIFYING, SOLICITING AND QUALIFYING MBE/WBE/DVBE SUBCONTRACTORS, DISTRIBUTORS AND VALUE ADDED RESELLERS. 

  

 103 

							
	 4.
	  		  	THE FOLLOWING INDIVIDUAL, ACTING IN THE CAPACITY OF MBE/WBE/DVBE COORDINATOR FOR SELLER, WILL:
			
		  		  	ADMINISTER THE MBE/WBE/DVBE PARTICIPATION PLAN, SUBMIT SUMMARY REPORTS, AND COOPERATE IN ANY STUDIES OR SURVEYS AS MAY BE REQUIRED IN ORDER TO DETERMINE THE EXTENT OF
COMPLIANCE BY THE SELLER WITH THE PARTICIPATION PLAN.

  

			
	NAME:	  	 
		
	TITLE:	  	 
		
	TELEPHONE NUMBER:	  	 
		
	AUTHORIZED SIGNATURE:	  	 
		
	DATE:	  	 

 Submit your annual plan to
sbcsd@att.com 
  

 104 

 Appendix H - MBE/WBE/DVBE Results Report 

For purposes of this Appendix H, Supplier refers to Motricity. 

M/WBE-DVBE QUARTERLY RESULTS REPORT 

FOR THE FOLLOWING AT&T AFFILIATE: 

 

 

 Note: Subcontracting Results should reflect ONLY M/WBE-DVBE dollars directly traceable to sales DURING THE
REPORTING QUARTER. 
 Results must be reported individually for each AT&T subsidiary. 

 

							
	 THIS SUMMARY REPORT SHOULD BE E-MAILED TO:
	  	sbcsd@att.com	  	
	 1. Reporting Company:
	  		  	
	 Company Name:
	  	 	  		  	
	 Address:
	  	 	  	2. Contract/ Work Order Number:	  	 3. Report Quarter:
  

This report reflects the utilization of Minority Business Enterprises/Women Business Enterprise/Disabled Veteran Enterprise participation for
period

	 City, State, Zip:
	  	 	  	  
	 Contact Name:
	  	 	  		  
	 Title:
	  	 	  		  
	 E-Mail:
	  	 	  		  
	 Date:
	  	 	  		  
	 Telephone:
	  	 	  	________________	  	
		  		  	(If Available)	  	 
	Signature:	  		  		  	Through
		  		  		  	 
		  		  		  	(Please indicate dates)

															
	PARTICIPATION GOAL	  	PARTICIPATION ACHIEVEMENT
				
	4.	  	Annual Goal	  	5.	  	Actual for Quarter
								
	Percent of Total Sales	  	MBE	  	WBE	  	DVBE	  		  	MBE	  	WBE	  	DVBE
								
		  		  		  		  	 Dollars paid by Prime
 Supplier
to Subcontractors
	  	 	  	 	  	 
								
		  		  		  		  	 Total Dollars Paid to
 Prime
Supplier by AT&T
	  	 	  	 	  	 
								
		  		  		  		  	% OF Total AT&T $ Paid by Prime Supplier to Subcontractors	  	 	  	 	  	 

  

 105 

 AT&T SUBCONTRACTING RESULTS 

 

									
	6. M/WBE-DVBE Subcontractors(S)	  	Ethnic/Gender	  		  	Total Dollars
					
		  		  	

	  		  	
	Name:	  	 	  	  		  	
	Address:	  	 	  		  		  	
	City, State, Zip:	  	 	  		  	Certifying Agency:	  	
	Telephone:	  	 	  	select from the drop down menu to see a list of AT&T recognized agencies     
q
	Goods or Services:	  	 	  		  		  	
		  		  		  	If other please specify:

 To add additional
Subcontractors, copy the entire light gray area and paste directly below this line. 
  

 106 

 EXHIBIT N – AT&T PRIVACY POLICY 

Effective date: October 21, 2006) 

AT&T has a long-standing policy of protecting customer privacy. 

We believe that you should know what information we collect from you, as well as how that information is used, disclosed, and protected. We have created
this policy statement (the “Policy”) to explain our privacy practices and policies. 
 We will not sell or disclose your personal
information to unaffiliated third parties without your consent except as otherwise provided in this Policy. We may use information about who you are, where and when you browse on the Web, where your wireless device is located, and how you use our
network to provide you better service and enrich your user experience when you sign up or use any of our products or services. 
 AT&T may
make available shorter or machine-readable versions of this Privacy Policy. These additional policies are intended only as summaries of this complete Privacy Policy. This Policy applies to customers who purchase and use our services and products in
the United States. Collection, use, disclosure, and protection of personal information may be subject to different regulation outside the United States. 

AT&T will revise and update this Policy as it deems appropriate, including, for example, if our practices change or if changes in the law so require.
You should refer back to this page for the latest information. 
 QUICK PRIVACY LINKS 

The following brief summaries outline our Policy and then link to further detail. We also provide you the means to communicate with us if you have any
questions about this Policy. This Policy also addresses what we do with information about your device usage, the services you buy from us, and who you call. 

Does AT&T Collect Personal Information About Me? 

Yes, AT&T collects personal information about you so that we can deliver products or services you request. 

 

 107 

 This happens automatically when you interact with us, such as when you log into a service. Sometimes,
AT&T buys commercially available marketing and sales information from third parties so we can better serve you. Tell me more 
 Does
AT&T Collect Information About Children Under the Age of 13? 
 If we make available offers and products online where a child informs us
that he or she is under the age of 13, we will ask a parent to confirm his/her consent in advance of further collection, use or disclosure of personal information from that child. 

How Does AT&T Use Personal Information? 

We use personal information for billing and collection purposes, to provide services or complete transactions you have requested, and to anticipate and
resolve problems with your services. We may also use this information to create and inform you of products or services from AT&T or others that may better meet your needs. 

When Does AT&T Disclose Personal Information? 

We do not sell personal information to unaffiliated third parties. We will disclose personal information to third parties to complete a transaction you
have requested, as part of the terms and conditions for a particular service, to collect on an account, or when we otherwise have your consent to do so. We also may disclose personal information to third parties to protect the rights and property of
the company or its subscribers. 
 What Happens to Information About My Telephone Usage and Who I Call? 

Under federal law, you have a right, and we have a duty, to protect the confidentiality of information about your device usage, the services you buy from
us, who you call, and the location of your device on our network when you make a voice call. 
  

 108 

 Does AT&T Use Cookies? 

Yes. AT&T uses cookies for a variety of reasons, including improving your shopping or browsing experience. In addition, cookies help us personalize
the site experience for you. 
 Does AT&T Use Web Beacons? 

Yes. AT&T uses Web beacons, also known as Web bugs, on our sites so that we can identify you and deliver you the services you request. However,
AT&T does not permit third parties to use Web beacons linked to personal information on our site. 
 Does AT&T Place Advertising on
Other Web Sites? 
 AT&T currently uses third-party advertising companies to place our ads on the Internet, and cookie and Web beacon
technologies are used to measure the effectiveness of those ads. You should know that the use of such cookies is subject to the third parties’ privacy policies, and not the policy of AT&T. 

What About Presence, Location, and Tracking Information? 

Our network knows the general location of your phone whenever it is turned on. When we offer you optional services that require use or disclosure of this
information, the terms and conditions for the specific service offering explain how the location information will be used. We also may provide your network location to emergency service providers if you place a 911 call. 

Can I Choose Not to Receive Marketing Messages on My Wireless Device from Third Parties? 

AT&T has implemented technology to reduce unsolicited bulk short text messages but is unable to filter all marketing messages that you receive on your
wireless device from third parties. 
  

 109 

 How Secure Is Information About Me? 

We maintain a variety of physical, electronic, and procedural safeguards to guard your personal information. 

What Can I Do to Protect My Personal Information? 

An important part of ensuring the security of your personal information is your own efforts to protect against unauthorized access to your wireless device
and SIM card. Before discarding your device or trading it in, be sure you remove all your personal information from the device. 
 How can I
Review Personal Information in my Account for Accuracy? 
 You can review the accuracy of the personal information in your account online (go
to My Account on this Web site) or by contacting Customer Service at 1-800-331-0500. 
 Will This Policy Be Updated? 

AT&T expects to update this Policy periodically. You should refer back to this page often for the latest information and the effective date of any
changes to the Policy. 
 To Whom Should I Direct Privacy Questions or Concerns? 

You have several ways to contact us about questions of this Policy and about your services. 

AT&T PRIVACY POLICY 
 We have created
the AT&T Privacy Policy (the “Policy”) to explain our privacy practices. When you use any AT&T product or service, you should understand when and how personal information is collected, used, disclosed and protected. 

 

 110 

 We will not sell or disclose information to unaffiliated third parties without your consent except as
otherwise provided in this Policy. We may use information about who you are, where and when you browse on the Web, where your wireless device is located, and how you use our network to provide you better service and enrich your user experience when
you sign up or use any of our products or services. 
 AT&T will revise and update this Policy if our practices change or if changes in the
law so require. 
 Information Collected About You 

We collect a variety of personal information about users of our products or services. Personal information is information that can be directly associated
with a specific person or entity, such as a name, address, telephone number, email address, or information about activities directly linked to that person. 

Our definition of personal information does not include “aggregate” information. Aggregate information is data we collect about a group or
category of services or customers from which individual customer identities have been removed. For example, we could prepare a report that indicates that a certain number of our customers always use their wireless phones at a certain time of day at
a specific location. Aggregate data helps us understand trends and customer needs so that we can better consider new services or tailor existing services to customer desires. The aggregate data also might be purchased by or shared with a third
party, for example, one interested in locating a business in a particular part of town. 
 Here are the types of personal and other information
we collect. You should refer to the rest of this Policy to see how we use, disclose, and protect that information: 
  

	 	•	 	 Information You Give Us 

We collect information you give us when you purchase an AT&T product or use services. For example, you may provide us a billing
address and credit information, including your social security number or 
 business identifier, when signing up for service or
perhaps purchasing a product through our online store. You might not have thought about it this way, but the numbers dialed from your wireless phone to make a call are an example of information you give us and that we collect and use so we can bill
you appropriately and investigate fraudulent usage. 
  

 111 

	 	•	 	 Automatically Collected Information 

We automatically receive certain types of information whenever you interact with us. For example, when you visit an AT&T Web site, our
systems automatically collect your IP address and the type of browser you use. When you browse the wireless web, our systems log the Web sites you visit. Similarly, all wireless communications systems know when your phone is turned on and
approximately where the device is physically located—that’s how calls or messages are delivered to you in real time. 
  

	 	•	 	 Information from Other Sources 

We may obtain information about you from outside sources and add it to or combine it with your account information. For example, we may
receive credit information for purposes of initiating service. We also may use commercially available demographic and marketing information from third parties to help us better serve you or inform you about products or services that we think will be
of interest to you. We sometimes receive updated delivery and address information from our shippers or other sources so that we can correct our records and deliver your next purchase or communication more easily. And, we often receive information
from the dealer from whom you purchase your wireless phone or device prior to initiating service with us. 
 We also may purchase email lists
from third parties for advertising purposes. We only purchase lists of individuals who have allowed third-party use of their email address for marketing purposes. If you have previously requested to participate in an email advertising program, the
information we receive may include your name, information on previous transactions, or any other personal information you have provided. 

AT&T recognizes that parents often purchase our products and services for family use, including for use by minors. Any information collected from
such usage will appear to be the personal information of the actual subscriber to the service, and will be treated as such under this Policy. If we make available offers and products online where a child informs us that he or she is under the age of
13, we will ask a parent to confirm his/her consent in advance of further collection, use or disclosure of personal information from that child. 

In a Business Agreement, our customer is a business or other entity purchasing service for employees or other authorized users. If you receive certain
benefits through a business or government customer’s agreement with us, 
 this Policy will generally govern your personal information.
However, if you receive service where a business or government entity pays AT&T for your account or is otherwise liable to AT&T for the charges (for example, as a guarantor if you fail to pay), we may share your account information with that
entity. If you receive certain benefits tied to a Business Agreement, but you are liable for your own charges, then we may share enough account information with that entity to verify your continuing eligibility for those benefits. Please contact
AT&T if you have any questions about who is the liable party on your bill. 
  

 112 

 Children’s Online Privacy Protection Act 

If we make available offers and products online where a child informs us that he or she is under the age of 13, we will ask a parent to confirm his/her
consent in advance of further collection, use or disclosure of personal information from that child. You should be aware, however, that wireless devices and services purchased for family use may be used by minors without the knowledge of AT&T.
If that happens, any information collected from the usage will appear to be the personal information of the actual adult subscriber and treated as such under this Policy. 

Use of Personal Information 
  

	 	•	 	 Internal Use. 

In general, we use personal information to serve our customers, to enhance and extend our customer relationship, and to enable our
customers to take maximum advantage of products and services we think they would enjoy. For example, by understanding how you use our Web site, we are able to customize and personalize your experience. More specifically, we use personal information
for billing purposes, to provide services or complete transactions you have requested, to anticipate and resolve problems with your services, and to create and inform you of products or services from AT&T or others that better meet your needs.

 AT&T uses email, short text messages, telemarketing, and direct mail to inform you about products or services we think
will interest you. You can modify your preferences on receiving these types of communications: 
  

	 	•	 	 If you are currently a AT&T customer and wish to change your preferences on receiving these types of communications, you can do one of the
following to tell us your preferences: 

  

	 	•	 	 Complete an online form 

  

	 	•	 	 Visit the “My Profile” page, if you manage your account online. 

 

	 	•	 	 Call Customer Service at 1-800-331-0500. 

  

 113 

	 	•	 	 If you are not a current customer of AT&T and wish to opt out of receiving marketing communications, you can complete an online form to tell us
your preferences. 

 While you may choose not to receive marketing information from us, you will continue to
receive invoices, customer service-related notifications, and other similar information from us electronically or otherwise. 
  

	 	•	 	 Third-Party Use. 

You should review the following section to understand when AT&T discloses personal information to third parties. 

Disclosure of Personal Information 

Information about our customers is one of our most important business assets, and therefore we strive to protect it and keep it confidential. We do not
sell personal information to third parties without your consent. When and what types of information AT&T discloses depends on the service and in some cases the choices you have made. 

AT&T will not disclose personal information other than in accordance with this Policy. In general, that means that you must consent to the disclosure
in advance. Depending on the service, we may obtain your consent in a number of ways, including: 
  

	 	•	 	 In writing; 

  

	 	•	 	 Verbally; 

  

	 	•	 	 Online by clicking a button; 

  

	 	•	 	 Through the use of a dialing string or button on a wireless device or handset; or 

 

	 	•	 	 At the time of initiation of a particular service offering, when your consent is part of the required terms and conditions to use that service.

 For example, your consent to disclose personal information can be implied simply by the nature of your request, such as
when you ask us to deliver an email or short message to another person. Your return address is disclosed as part of the service and your consent to do so is implied by your use of the service. To determine how personal information may be disclosed
as part of a particular service, you should review the terms and conditions of use for that service. 
  

 114 

 We share personal information with third parties as necessary to complete a transaction, perform a service
on our behalf (such as enhancing our ability to serve you better), or perform a service that you have requested. When the third party acts solely on our behalf, AT&T does not allow them to use your information for other purposes. For example,
our vendors process and print your billing statement on our behalf. They can only use the personal information we give them to produce the billing statement. When we write off an account for non-payment, AT&T sometimes discloses personal
information about the account to third parties such as credit bureaus. Credit bureaus may use the personal information to update their records. AT&T does not currently disclose wireless numbers in AT&T listings or published directories. If
we do so in the future, you will be able to choose whether your number is listed. 
 Aside from our services, however, you may also want to take
advantage of services and products offered by other companies utilizing our wireless service. In those cases, you will be providing information to those companies, and information about you received by those third parties will be governed by their
privacy policies, not this Policy. For example, if you are roaming on the network of another carrier, information about your usage and the numbers you dial will be available to the carrier providing the service. Also, as another example, if you
purchase something using our mobile Internet service, you will be disclosing personal information directly to the company facilitating the transaction, a merchant bank and the merchant. Finally, if you bought your wireless device from a third party
retailer or dealer, both they and AT&T will have personal information as a result of the transaction and your ongoing service with AT&T. Whenever third parties have a role in any such transaction, you should review their privacy policies as
well. 
 From time to time you may be able to participate in contests, giveaways, or other similar promotions we sponsor. Except as explained
otherwise in the rules for a particular contest, giveaway, or promotion, any personal information you provide will be used in accordance with this Policy. 

In addition, from time to time you may be able to participate in our surveys to help us improve our offerings and services. Except as explained otherwise
in the survey, any personal information so collected will be used for our internal purposes. 
 Under federal law, you have a right, and we have
a duty, to protect the confidentiality of information about your telephone usage, the services you buy from us, who you call, and the location of your device on our network when you make a voice call. This information is sometimes referred to as
“Customer Proprietary Network Information,” 
  

 115 

 
or “CPNI.” We share CPNI and other personal information about you with affiliates of AT&T and BellSouth Corporation (the parent companies of AT&T) that provide
telecommunications services to which you also subscribe. Before sharing CPNI in any other way, we will first notify you of your rights under the law, describe how we intend to use the CPNI, and give you an opportunity to opt out of such usage (or,
when required by law, to opt in). 
 Business Transfers: 

Information about our users, including personal information, may be disclosed as part of any merger, acquisition, sale of company assets, or transition of
service to another provider, as well as in the unlikely event of an insolvency, bankruptcy, or receivership in which personal information would be transferred as one of the business assets of the company. 

Protection of AT&T and Others: 
 We
release personal information when we believe release is appropriate to comply with the law or in good faith reliance on legal process (e.g., court orders, subpoenas, E911 information, etc.); enforce or apply our customer agreements; initiate,
render, bill, and collect for services; protect our rights or property, or protect users of those services and other carriers from fraudulent, abusive, or unlawful use of, or subscription to, such services; facilitate or verify the appropriate
calculation of taxes, fees, or other obligations due to a local, state, or federal government; or if we reasonably believe that an emergency involving immediate danger of death or serious physical injury to any person requires disclosure of
communications, or justifies disclosure of records, to a governmental entity without delay. 
 AT&T Use of Cookies 

Cookies are small files placed on your computer’s hard drive by a Web site when you visit. These files identify your computer and record your
preferences and other data about your visit so that when you return to the site, the site knows who you are and can personalize your visit. For example, cookies enable a Web site shopping cart to function so that you only have to check out once.
Consequently, cookies are often tied to the use of personally identifiable information while using our site, and some functionality may be lost if you choose not to accept the use of cookies. 

 

 116 

 In general, we use cookies to collect information so that we can determine how to improve our site by seeing
which areas, features and products are most popular; to personalize the site and make recommendations based on products you have liked in the past as well as to improve the site experience; and to complete transactions you have requested.
Advertisers that serve ads on our site may also use their own cookies. Such outside cookies are governed by the privacy policies of the entities placing the ads, and are not subject to this Policy. 

We also use a session-based cookie that maintains a user’s session for continuity of navigation while viewing the site. After closing the browser
the session cookie simply terminates. 
 With wireless Internet service, cookies are also used by our suppliers and third-party vendors to
facilitate the various services and information offered. Depending on the phone or device being used, cookies may be stored locally on the phone or device, or on servers operated by AT&T. This Internet cookie-like functionality is in place for
the same reasons and designed for the same purposes as cookies placed on your computer when interacting with Internet Web sites. Our suppliers and vendors will only use this information to provision the service, but each site you visit while using
the wireless Internet service is controlled by a separate company and their individual privacy policies will govern information they receive automatically from the cookie or information you voluntarily provide. 

AT&T Use of Web Beacons 
 A Web
beacon, also known as a Web bug, is a small, graphic image on a Web page, Web-based document or in an email message that is designed to allow the site owner or a third party to monitor the address and other information of the computer viewing the
item. Web beacons are often invisible to the user because they are typically very small (only 1-by-1 pixel) and the same color as the background of the Web page, document, or email message. Web beacons are represented as HTML IMG tags in the Web
page; users can click on “view profiles” of the Web page to see whether the page is using a Web beacon. Web beacons collect the IP address of the computer that the Web beacon is sent to, the URL of the page the Web beacon comes from, and
the time it was viewed. Web beacons can also be linked to personal information. 
 AT&T does not place Web beacons that link to personal
information on other sites, nor does it permit third parties, other than those working on our behalf, to place them on our site. AT&T does use Web beacons itself and may link a particular beacon to personal information. For example, we may use a
beacon to ensure a user can flip between technical assistance, customer service and our online store and still be recognized as our customer. 
  

 117 

 AT&T Placement of Advertising on Other Web Sites 

AT&T may use third-party ad serving companies to place advertisements about our products and services on other Web sites. These companies may use
cookies and other technology such as Web beacons or tagging to measure the effectiveness of our ads. To measure advertising effectiveness and offer selective ad content, the ad serving companies may use anonymous information about your visits to our
and other Web sites. But the ad serving companies use an anonymous number to identify you, NOT your name, address, phone number, email address, or anything that personally identifies you. The use of such cookies is subject to the ad serving
company’s privacy policy, not the Policy of AT&T. If you would like more information about these companies we use, their privacy practices, or to learn your choices about not having this non-personal information used to serve ads to you,
see our AT&T Ad Serving Companies. 
 AT&T Advertising Companies 

This list contains a link to the privacy policies for the ad-serving companies used to place ads on 3rd party sites. AT&T will revise or update this
as we change existing or add new ad-serving companies. 
  

	 	•	 	 Avenue A and Atlas 

Presence, Location, and Tracking 
 To
make wireless communications possible, the network knows the general location of your phone or wireless device whenever it is turned on. Your wireless device sends out a periodic signal to the nearest radio tower/cell site so that the network will
know where to route an incoming communication and how to properly bill for the service. This is necessary to make wireless communications possible. 

If you dial 911 for emergency services, we may provide your network location to a public safety answering point, emergency medical service provider or
emergency dispatch provider, public safety, fire service, or law enforcement official, or hospital emergency or trauma care facility. The law also permits us to disclose the location of a device on our network without a user’s consent
(1) to a user’s legal guardian or members of a user’s 
  

 118 

 
immediate family in an emergency situation that involves the risk of death or serious physical harm, (2) to database management services or information providers solely to assist in
delivering emergency services, or (3) to a governmental entity if we reasonably believe that an emergency involving immediate danger of death or serious physical injury to any person requires or justifies disclosure of a device’s location
on the network without delay. Legally required upgrades will allow us to provide a location more precise than cell site location. 
 In
addition, we offer optional services on our GSM/GPRS network that make use of your network location. Please review the terms and conditions for each service for additional information about how the location information will be used. The location
used for these services is separate from the network location information when you make a voice call. 
 Your wireless Internet service may also
be personalized using your ZIP code or other location identifiers. We use this information to serve you relevant content, and we treat the information like any other personal information under this Policy. This service does not use the network
location technology described in this section. 
 Receipt of Marketing Messages on My Wireless Device from Third Parties 

You should be aware that not all advertisements appearing on or delivered to your mobile phone or device are authorized by AT&T. We have developed and
implemented systems in our network to reduce unsolicited bulk short text messages, but we cannot at this time block all such messages. We continue to look for other options to reduce these unsolicited bulk messages. If you have an email account with
AT&T, this service is subject to unsolicited messages as any other email service. 
 It is unlawful for any third party to make an
unsolicited telemarketing call using an autodialer or to send a prerecorded message to a wireless phone or device. You should report any such unsolicited calls to the Federal Communications Commission. 

 

 119 

 Network and Information Security 

We maintain a variety of physical, electronic, and procedural safeguards to guard your personal information. For example, we use accepted tools and
techniques to protect against unauthorized access to our systems. Also, we grant access to personal information about you to employees and contractors who need to know that information to provide products or services to you. In addition, we work to
protect the security of your personal information when you are ordering new service via the AT&T Web site by using well-known Internet encryption technologies like Secure Sockets Layer (SSL). We also use encryption technologies to protect your
account information when you are viewing your bill on our Web site. You should be aware that AT&T has no control over the security of other sites on the Internet you might visit, interact with, or from which you buy products or services.

 What Can I Do to Protect My Personal Information? 

An important part of ensuring the security of personal information is your own effort to protect against unauthorized access to your wireless device and
the personal information contained in it and on your SIM card. Most phones and wireless PDA-type devices store calling information both in the phone and on the SIM card. Therefore, before discarding your phone or PDA, trading it in or giving it
away, be sure you remove and retain your SIM card and follow the manufacturer’s instructions for deleting all personal information on the device itself. (This can be found in your owner’s manual or on the manufacturers’ Web site.)

 In addition, use passwords to prevent unauthorized access to your wireless device, your wireless service account, and your voicemail. If you
write down your passwords or user names, keep the information in a secure location. Do not give your password to someone else unless you intend them to have the same full access and ability to make changes to your account as you have. Change your
passwords periodically. 
 Accuracy of Personal Information in Your Account 

You can review the accuracy of the personal information in your account records online (go to My Account on this Web site) or by contacting Customer
Service at 1-800-331-0500. 
 California customers: AT&T does not disclose customers’ personal information to third parties for
the third parties’ direct marketing purposes, as governed by California Civil Code 1798.83. 
  

 120 

 Updating this Policy 

AT&T will revise or update this Policy as it deems appropriate, including for example, if our practices change, as we change existing or add new
services, as we develop better ways to inform you of products we think will be of interest, or if the law so requires. You should refer back to this page often for the latest information and the effective date of any changes. 

If, however, users’ personally identifiable information will be used in a manner materially different from that stated at the time of collection, we
will notify users via posting on this page for 30 days before the material change is made. Users will have a choice as to whether or not their information will be used in this materially different manner. 

Contact Us 
 AT&T is committed to the
policies set forth in this Policy. 
 If you have any questions, comments or concerns about this Policy, please contact privacy@att.com.

 If you have questions about your AT&T service, you can call a customer service representative at 1-800-331-0500. 

 

 121 

 THIRD AMENDMENT 

TO THE SECOND AMENDED AND RESTATED 

WIRELESS SERVICES AGREEMENT #00014249 

This Third Amendment (this “Third Amendment”) to the Second Amended and Restated Wireless Services Agreement #0001429 of July, 22, 2005 between
Motricity, Inc., f/k/a InfoSpace Mobile, Inc. (“Motricity” or “Supplier”) and AT&T Mobility LLC (“AT&T Mobility” or “AT&T”) (the “Agreement”), is made and entered into this 11th day of
June, 2009 (“Third Amendment Effective Date”). Such parties are referred to herein individually as a “Party,” and collectively as the “Parties”. 

WHEREAS, InfoSpace has provided certain Services to AT&T Mobility pursuant to the Agreement; 

WHEREAS, Cingular Wireless LLC changed its name to AT&T Mobility LLC on January 8, 2007; 

WHEREAS, InfoSpace Inc. changed its name to Motricity, Inc. on December 28, 2007 and assumed all of the rights and obligations of InfoSpace
Mobile, Inc.; 
 WHEREAS, Motricity, Inc. and AT&T entered into that certain First Amendment to the Agreement on March 1, 2007
(the “First Amendment”); 
 WHEREAS, Motricity, Inc. and AT&T entered into that certain Second Amendment to the Agreement
on October 1, 2008 (the “Second Amendment”); and 
 WHEREAS, Motricity and AT&T desire to perpetuate and continue
their relationship, by doing business under the terms of the Agreement, as amended as set forth herein. 
 NOW, THEREFORE, in
consideration of the premises and the covenants hereinafter contained, the Parties hereto agree as follows: 
  

	1.	Except as otherwise provided herein, all of the terms, covenants and conditions used, but not defined, herein shall have the meanings ascribed to them in the Agreement.
In the event of a conflict between the terms and conditions hereof, and the terms and conditions of the Agreement, the specific terms and conditions set forth in this Third Amendment shall govern. 

 

	2.	Section 1 “Definitions” of the Agreement shall be amended to add/delete/modify the following definitions (as noted below). Additional definitions may be
found within the Agreement and related Amendments. 

 “ATT.Net Active User” means a Subscriber for whom Motricity
reports one or more ATT.Net Sessions during a calendar month. 
 “ATT.Net Portal User” means each unique profile for a
Subscriber that has used the Service, which profile may be derived from information (or a combination of information) that may include screen name, user identifier, device identifier and/or MSISDN. 

“ATT.Net Session” means a registered connection to the Service, as measured by Motricity. 

“ATT.Net Service” means the next generation wireless internet that will allow AT&T subscribers to easily find, consume and save
global web content, to find people, places and things in the local area and to browse and save popular editorial content. Further, the ATT.Net Service will also allow Subscribers to have a consistent internet experience via a fully optimized HTML
browser that enables interactivity, lower latency for a richer internet experience. 
  

 1 

 “AT&T Property” means physical and non-physical property of AT&T (or provided on
behalf of AT&T), including materials, equipment, software, hardware, networks, IT systems and network connectivity. 
 “Commercial
Launch” is defined as the date where the ATT.Net Service is to be made available to Subscribers, on July 20, 2009. 

“Motricity’s Span of Control” means Motricity’s facilities physical infrastructure (including external power sources),
supporting network elements, web-to-the-Motricity network demarcation point, support services, hardware and software associated with the Service that is under Motricity’s control (e.g. functionality that is provided by external vendors or
suppliers with whom Motricity has a contractual relationship, including feeds from providers of Motricity Sourced Content). This includes the System and its components for the transmission and control, security of network and data, physical
security, software and user data including backup data; all hardware and software used in connection with backing up data; and all Motricity employees and subcontractors participating in the provisioning of the Service. Motricity’s Span of
Control does not include the services and systems that are under the control of AT&T or its third party suppliers and service providers, including AT&T’s MMS Center and all other elements of the AT&T network nor does it include
functionality or feeds from providers of content not under a contractual relationship with Motricity . 
 “Device(s)” means the
AT&T designated mobile device(s) that are certified or will be certified for use on the AT&T network in support of the AT&T commercial service offering (e.g.,ATT.Net Service, MEdia Net Service, etc.). 

“Device Client” means the Software that conforms to a specific Device or set of Devices. 

“Device Client Services” has the meaning set forth in Exhibit A-3 – Services, attached hereto and incorporated herein. 

“Device Client Support Obligations” has the meaning set forth in Section B (5.4.1) of Exhibit A-3 – Service. 

“DCS” means Device Client Service. 

“DCS Failure(s)” has the meaning set forth in Section B (5.5.1) of Exhibit A-3 – Service. 

“Documentation” means any user manuals, operator instructions, training material, developers’ guides and other written materials
used in conjunction with the Service and/or Software and provided by Motricity, whether in printed or electronic form. 
 “Motricity
Software” is deleted and replaced with the Software” as defined in this Third Amendment. 
 “Motricity Supported
Handsets” is deleted and replaced with “Devices” as defined in this Third Amendment. 
 “Level of Effort”
has the meaning set forth in Section B (10) of Exhibit A-3 – Services. 
 “OEM” means original equipment
manufacturer and refers to the Device manufacturer. 
 “Partner Integration Services” has the meaning set forth in Section B
(6) of Exhibit A-3 – Services. 
 “QA” means Quality Assurance. 

 

 2 

 “Service Agreement” is as defined in Section 19 of the Second Amendment to the
Agreement. 
 “Software” means the software designed, developed, manufactured or provided by, or on behalf of, Motricity as
part of the Service. 
 “Specifications” means (i) Motricity’s applicable technical and functional documents and
descriptions, including any warranty statements, and (ii) AT&T’s written requirements, technical documents and descriptions, specified in or attached to this Agreement, an executed Statement of Work, Work Order or Purchase Order, which
shall control over any inconsistency with Motricity’s specifications and description. 
 “Statement(s) of Work” means
written description of the professional services, custom development and service requests for new Services, pursuant to the terms and conditions of the Services Agreement. 

“Subscriber” means a unique AT&T end user of the ATT.Net Service, MEdia Net Service or Legacy Services as authenticated by Motricity
and depending upon the context. 
 “System” means that AT&T Property and any or all platforms, databases, software, Product
and API(s) provided by, or on behalf of, Motricity that support the Service 
 “Web/WAP Services” has the meaning set forth in
Section B (7) of Exhibit A-3 – Services. 
  

	3.	The Agreement is amended to add a new paragraph to Section 2.1 as follows: 

Motricity Grant for ATT.Net Service. Notwithstanding the preceding paragraph, the license grant applicable to the ATT.Net Service
is as set forth within Section 5.6 of Exhibit A-3. 
  

	4.	Limitations. Section 2.3 (a) is deleted in its entirety and replaced with the following: 

 

	 	(a)	AT&T shall have no right by virtue of this Agreement to reproduce or sub-license, re-sell or otherwise distribute all or any portion of the Motricity Content, or
Services under this Agreement to any Person, other than providing access to the Motricity Content and Services to Users. 

  

	5.	AT&T Obligations. Section 3.2, the following language is deleted it its entirety: 

“Notwithstanding the above, should AT&T choose to host this service with anyone other than Motricity, this section will no longer
apply.” 
 And replaced with the following: 

“Notwithstanding the above, as it relates to the ATT.Net Service and/or when AT&T hosts the service on its own or with anyone
other than Motricity, this section will no longer apply.” 
  

	6.	Insurance. Section 6.4 of the Second Amendment is deleted in its entirety and replaced with the following: 

 

	 	6.4.1	With respect to Motricity’s performance under this Agreement, and in addition to Motricity’s obligation to indemnify, Motricity shall at its sole cost and
expense: 

  

	 	6.4.1.1	maintain the insurance coverages and limits required by this Section and any additional insurance and/or bonds required by law: 

 

	 	6.4.1.1.1 	at all times during the term of this Agreement and until completion of all Work associated with this Agreement, whichever is later; and 

 

 3 

	 	6.4.1.1.2 	with respect to any coverage maintained in a “claims-made” policy, for two (2) years following the term of this Agreement or completion of all Work
associated with this Agreement, whichever is later. If a “claims-made” policy is maintained, the retroactive date must precede the commencement of Work under this Agreement; 

 

	 	6.4.1.2	require each subcontractor who may perform Work under this Agreement or enter upon the Work site to maintain coverages, requirements, and limits at least as broad as
those listed in this Section from the time when the subcontractor begins Work, throughout the term of the subcontractor’s Work and, with respect to any coverage maintained on a “claims-made” policy, for two (2) years thereafter;

  

	 	6.4.1.3	procure the required insurance from an insurance company eligible to do business in the state or states where Work will be performed and having and maintaining a
Financial Strength Rating of “A-” or better and a Financial Size Category of “VII” or better, as rated in the A.M. Best Key Rating Guide for Property and Casualty Insurance Companies, except that, in the case of Workers’
Compensation insurance, Motricity may procure insurance from the state fund of the state where Work is to be performed; and 

  

	 	6.4.1.4	deliver to AT&T, certificates of insurance stating the types of insurance and policy limits. Motricity shall provide or will endeavor to have the issuing insurance
company provide at least 30 days advance written notice of cancellation, non-renewal, or reduction in coverage, terms, or limits to AT&T. Motricity shall deliver such certificates: 

 

	 	6.4.1.4.1 	prior to execution of this Agreement and prior to commencement of any Work; 

 

	 	6.4.1.4.2 	prior to expiration of any insurance policy required in this Section; and 

  

	 	6.4.1.4.3 	for any coverage maintained on a “claims-made” policy, for two (2) years following the term of this Agreement or completion of all Work associated with
this Agreement, whichever is later. 

  

	 	6.4.2	The Parties agree: 

  

	 	6.4.2.1	the failure of AT&T to demand such certificate of insurance or failure of AT&T to identify a deficiency will not be construed as a waiver of Motricity’s
obligation to maintain the insurance required under this Agreement; 

  

	 	6.4.2.2	that the insurance required under this Agreement does not represent that coverage and limits will necessarily be adequate to protect Motricity, nor be deemed as a
limitation on Motricity’s liability to AT&T in this Agreement; 

  

	 	6.4.2.3	Motricity may meet the required insurance coverages and limits with any combination of primary and Umbrella/Excess liability insurance; and 

 

	 	6.4.2.4	Motricity is responsible for any deductible or self-insured retention. 

  

	 	6.4.3	The insurance coverage required by this Section includes: 

  

	 	6.4.3.1	Workers’ Compensation insurance with benefits afforded under the laws of any state in which the Work is to be performed and Employers Liability
insurance with limits of at least: 

 $500,000 for Bodily Injury – each accident 

 

 4 

 $500,000 for Bodily Injury by disease – policy limits 

$500,000 for Bodily Injury by disease – each employee 

To the fullest extent allowable by Law, the policy must include a waiver of subrogation in favor of AT&T, its Affiliates, and their
directors, officers and employees. In states where Workers’ Compensation insurance is a monopolistic state-run system, Motricity shall add Stop Gap Employers Liability with limits not less than $500,000 each accident or disease.

  

	 	6.4.3.2	Commercial General Liability insurance written on Insurance Services Office (ISO) Form CG 00 01 12 04 or a substitute form providing equivalent coverage,
covering liability arising from premises, operations, personal injury, products/completed operations, and liability assumed under an insured contract (including the tort liability of another assumed in a business contract) with limits of at least:

 $2,000,000 General Aggregate limit 

$1,000,000 each occurrence limit for all bodily injury or property damage incurred in any one (1) occurrence 

$1,000,000 each occurrence limit for Personal Injury and Advertising Injury 

$2,000,000 Products/Completed Operations Aggregate limit 

$1,000,000 each occurrence limit for Products/Completed Operations 

$1,000,000 Damage to Premises Rented to You (Fire Legal Liability) 

The Commercial General Liability insurance policy must: 

 

	 	6.4.3.2.1 	include AT&T, its Affiliates, and their directors, officers, and employees as Additional Insureds. Motricity shall provide a copy of the Additional Insured
endorsement to AT&T. The Additional Insured endorsement may either be specific to AT&T or may be “blanket” or “automatic” addressing any person or entity as required by contract. A copy of the Additional Insured
endorsement must be provided within 60 days of execution of this Agreement and within 60 days of each Commercial General Liability policy renewal; 

  

	 	6.4.3.2.2 	include a waiver of subrogation in favor of AT&T, its Affiliates, and their directors, officers and employees; and 

 

	 	6.4.3.2.3 	be primary and non-contributory with respect to any insurance or self-insurance that is maintained by AT&T. 

 

	 	6.4.3.3	Business Automobile Liability insurance with limits of at least One Million Dollars ($1,000,000) for each accident for bodily injury and property damage,
extending to all owned, hired, and non-owned vehicles. 

  

	 	6.4.3.4	Umbrella/Excess Liability insurance with limits of at least One Million Dollars ($1,000,000) for each occurrence with terms and conditions at least as broad as
the underlying Commercial General Liability, Business Auto Liability, and Employers Liability policies. Umbrella/Excess Liability limits will be primary and non-contributory with respect to any insurance or self-insurance that is maintained by
AT&T Mobility. 

  

 5 

	 	6.4.3.5	Professional Liability (Errors & Omissions) insurance with limits of at least One Million Dollars ($1,000,000) for each claim or wrongful act.

  

	7.	Term. Section 7.1(a) of the Agreement shall be deleted in its entirety and replaced with the following: 

 

	 	(a)	The term of this Agreement shall commence on the Effective Date and, unless earlier terminated pursuant to this Agreement, or except as provided in Section 7.1(b)
or (c), shall end on April 22, 2011 (the “Initial Term”). After the Initial Term, this Agreement shall continue until terminated by either Party upon six months notice. 

 

	8.	Termination for Convenience. Section 7.3.1 of the “Agreement” shall be deleted in its entirety and replaced with the following:

  

	 	7.3.1	Agreement. Effective April 22, 2011, AT&T may terminate this Agreement without cause upon six (6) months advance written notice. Termination for
convenience does not apply to Motricity. 

  

	9.	Section 7.4 “Obligations upon Termination or Transition of Service” is hereby amended to add a new section 7.4.6 as follows: 

 

	 	7.4.6.	Deliver AT&T Property to AT&T with AT&T paying any fees or other costs associated with such delivery and the transfer of any service agreements to AT&T
related to the AT&T Property. 

  

	10.	Exhibit A - “Services” is hereby amended to incorporate the terms described in Exhibit A-3 Services. 

 

	11.	Exhibit C - “Commercial Terms” is hereby amended to incorporate the terms described in Exhibit C-3 Commercial Terms, attached hereto and incorporated herein.

  

	12.	Exhibit G-2 “Service Level Agreement for WEB Services” found within Amendment No. 2 to the Agreement and is hereby amended to incorporate the terms
described in Exhibit G-2 Supplement, attached hereto and incorporated herein. 

  

	13.	This Agreement is hereby amended to add Exhibit G-3 “Service Level Agreement for ATT.Net Services” attached hereto and incorporated herein.

  

	14.	Exhibit J “Form of Work Order and Purchase Order” is hereby deleted in its entirety and replaced with Exhibit J “Work Order Form” to accommodate the
Device Client Services. 

  

	15.	The terms and conditions of the Agreement in all other respects remain unmodified and in full force and effect. 

 

 6 

 IN WITNESS WHEREOF, Motricity and AT&T have each caused this Third Amendment to be executed by its duly
authorized representative, which may be in duplicate counterparts, each of which will be deemed to be an original instrument, as of the Third Amendment Effective Date above. 

 

									
	MOTRICITY, INC.	 		 	AT&T SERVICES, INC.
		 		 	On behalf of its Affiliate AT&T Mobility LLC
					
	By:	 	/s/ Ryan Wuerch	 		 	By:	 	***
	Print Name:	 	 Ryan Wuerch
	 		 	Print Name:	 	 ***

	Title:	 	 Chairman & CEO
	 		 	Title:	 	 President, Supply Chain and Flleet Operations

		 	 6/26/09
	 		 		 	 7-7-09

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 7 

 EXHIBIT A-3 – SERVICES 

TABLE OF CONTENTS - SUPPLEMENT 

Exhibit A – Services is amended to insert the table of contents to reflect updates to Section headers and numbering sequence as of the Third
Amendment Effective Date: 
  

			
	 A.     Services
	  	
		
	 B.     Description of Services.
	  	
		
	 1.      Platform and Services; Legacy Services
	  	
		
	 (a)    Platform and Services
	  	
		
	 (b)    Legacy Services
	  	
		
	 2.      Content
	  	
		
	 (a)    AT&T Sourced Content
	  	
		
	 (i)     Integration with AT&T Sourced Content
	  	
		
	 (b)    Motricity Sourced Content
	  	
		
	 (i)     Modification of Motricity Sourced Content
	  	
		
	 3.      PIM/Email Service
	  	
		
	 3.      Personalized/Customized Content
	  	
		
	 4.      Device Client Services in support of ATT.NET Service
	  	
		
	 5.      Partner Integration Services
	  	
		
	 6.      Web and/or WAP Services
	  	
		
	 7.      Service Requests and Levels of Effort
	  	
		
	 C.     Motricity Supported Devices
	  	
		
	 1.      Current Devices
	  	
		
	 2.      New Devices
	  	
		
	 a.      MEdia Net and Legacy Services
	  	
		
	 b.      ATT.Net Service
	  	
		
	 3.      AT&T Network; Gateways
	  	
		
	 4.      Additional Support
	  	
		
	 D.     Reporting
	  	
		
	 (a)    Usage Reports
	  	
		
	 (b)    Legacy Usage Reports
	  	
		
	 (c)    Legacy Alert Reports
	  	
		
	 (d)    General Services Report
	  	
		
	 E.     Research and Development
	  	
		
	 F.     Research and Development Remedies
	  	
		
	 G.     Securities and Fair Disclosure
	  	

  

 8 

 EXHIBIT A-3 – SERVICES 

Exhibit A – Services is amended to add the following terms in support of the ATT.Net Service, which is in addition to the Services Motricity
is already providing to AT&T under the Agreement. 
 For the avoidance of doubt, the terms of this Exhibit A-3 controls in the event of any
conflict with other provisions of the Agreement, solely as it pertains to the ATT.Net Service. 
  

	A.	Motricity Services that support ATT.Net Service. 

Motricity will provide AT&T with the Device Client Services, Partner Integration Services, Web/WAP Service, and a System in support of
the ATT.Net Service (each of which may be referred to individually as a “Service” or collectively as “Services”) and in conformance with the Specifications and Documentation and the Performance Requirements set forth within the
Service Level Agreement. 
  

	B.	Description of Services. The following provisions are hereby incorporated into Exhibit A. 

 

	 	5.	Device Client Service 

Motricity will provide AT&T with device client development, integration and OEM support as set forth within this Section and pursuant
to the Specifications in support of the ATT.Net Service (“Device Client Service(s)”). 
  

	 	5.1	General. 

 Unless
otherwise specified by AT&T, Motricity will support a minimum of twenty-eight (28) launched Devices up to maximum of sixty (60) Devices, within a given calendar year, as follows: 

 

	 	5.1.1	Motricity will support both downloadable clients (“Downloadable Client(s)”) and embedded and integrated clients (“Preloaded Client(s)”).

  

	 	5.1.2	For Devices that support Downloadable Clients, Preloaded Clients or are mutually agreed upon (e.g., Research In Motion (RIM) Blackberry), Motricity will launch Devices
at no cost to AT&T. 

  

	 	5.1.3	For purposes of clarity, Devices requiring re-certification (as part of an OEM maintenance release and where there is no impact to the Device Client) will not be
subject any additional fees. 

  

	 	5.1.4	The Parties acknowledge and agree that Motricity’s ability to meet its Device Client Service responsibilities is contingent upon the cooperation of the respective
OEMs. Motricity will act in good faith to provide its Device Client Services in order to fulfill its obligations to provide the Managed Service. Provided Motricity is in full compliance with its Device Client Service responsibilities,
Motricity will not be held accountable for Device Client Service responsibilities outside of Motricity’s Span of Control. 

  

	 	5.1.5	For any mass migration of existing MEdia Net or Legacy Services to ATT.Net Service, the Parties agree to establish a baseline project schedule to handle any such
migration, document the appropriate acceptance criteria and remedies (if any) that would apply to the mass migration. 

  

 9 

	 	5.1.6	Test Environments. Motricity currently provides demo environments for testing. If it is determined that additional environment(s) are required for this, then
AT&T will reimburse Motricity for all fees associated with building it and will agree to pay Incremental Hardware and Software fees attributed to hosting this additional test environment as business as usual. 

 

	 	5.2	OEM Support 

  

	 	5.2.1	Motricity shall be responsible for facilitating/maintaining the OEM relationship to allow for the successful downloading, pre-loading and/or embedding of the Device
Client. 

  

	 	5.2.2	Motricity shall be responsible for the technical integration of the Device Client. 

 

	 	5.2.3	Motricity shall provide AT&T’s OEM partners with the following: 

  

	 	(i)	the Device Client 

  

	 	(ii)	Detailed documentation and integration tools 

  

	 	(iii)	Integrated test environment hosted by Motricity. 

  

	 	(iv)	Integration support staff 

  

	 	(v)	Device Client license to embed and distribute the Device Client for the ATT.Net Service 

 

	 	5.2.4	Device Client shall support the following: 

  

	 	(i)	application platforms that include, but are not limited to, Java (J2ME), Symbian, Android, Qualcomm Brew and Windows Mobile (“ Application Platforms”); and

  

	 	(ii)	AT&T OEM partners which includes but is not limited to, LG, Samsung, Nokia, SonyEricsson, Motorola, HTC, and RIM and the related Application Platforms.

  

	 	5.2.5	Motricity shall support native (embedded) OEM client integration upon request by AT&T to fulfill its obligations in providing the Managed Service to AT&T.
AT&T and Motricity will establish Level of Effort under a separate Service Request Form, pursuant to Section 10 of this Exhibit A-3 when OEMs do not comport with AT&T Requirements for standard application programming interfaces and the
Parties will determine what, if any additional fees are applicable. 

  

	 	5.3	OEM Support Fees 

  

	 	5.3.1	OEMs selected by AT&T shall not pay to Motricity any fees and/or costs for: 

 

	 	(i)	the Device Client; 

  

 10 

	 	(ii)	the Device Client license to embed and distribute the Device Client; or 

  

	 	(iii)	integration services 

  

	 	5.3.2.	Subject to Section 5.2.5 above, AT&T shall not pay Motricity to support native (embedded) OEM client integrations. 

 

	 	5.4	Device Client Support 

  

	 	5.4.1	The Parties will abide by the mutually agreed-upon Device Client Service and Device Onboarding Plan and the provisions of this Section 5 Device Client Service
(hereinafter referred to as “Device Support Obligations”) to be completed no later than thirty (30) days post Commercial Launch. 

  

	 	5.4.2	The Device Support Obligations includes the following: 

  

	 	•	 	 Process for AT&T to provide Motricity notification of devices to be pre-loaded and/or embedded and integrated; 

 

	 	•	 	 Process for Motricity to commence integration services with the Device OEM; 

 

	 	•	 	 Process for Parties project planning; 

  

	 	•	 	 Process for Motricity client porting and integration; 

 

	 	•	 	 Process for AT&T acceptance and defect resolution; and 

 

	 	•	 	 Status Reporting of Devices (e.g. build complete, commercially available, in progress and failures). 

 

	 	5.5	Remedies 

  

	 	5.5.1	Motricity shall track and report to AT&T on a monthly basis all instances where Motricity is unable to meet the Device Client Support Obligations in support of the
current month’s technical acceptance Device schedule (for reasons within Motricity’s Span of Control) for each Device (“DCS Failures”). 

 

	 	5.5.2	Remedies. If Motricity is unable to meet its Device Client Services listed in Section 5 above in any three calendar months within any four month period, then, at
the end of any such third failed month, AT&T shall have the right, in its sole discretion, to terminate the Agreement for cause upon thirty (30) days prior written notice to Company or to provide Company notice of AT&T’s intent to
develop a “Get Well Plan.” In the event that AT&T delivers a “Get Well Plan” notice, the Parties will use good faith efforts to agree to and execute on a plan for Company to remedy the applicable performance failures and meet
the Device Client Services set forth in Section 5. Upon implementation of any such mutually agreed plan, a new four month measurement period to determine compliance with the Device Client Services will commence. The foregoing remedy shall not
be an exclusive remedy and AT&T shall continue to have all rights and remedies available to it at law and in equity. 

  

 11 

	 	5.6	Motricity License Grants – ATT.Net Service. 

  

	 	5.6.1	Motricity grants to AT&T a limited, non-exclusive, non-transferable, non-sublicenseable, worldwide license to use the Service provided hereunder (to include any
Software on systems under AT&T’s control or AT&T supplied Device), and solely in connection with AT&T’s operation of the AT&T.Net Service and for the term of such Service and solely in accordance with the applicable
instructions or documentation and any end-user license restrictions, if applicable and if provided to AT&T in writing in advance. 

  

	 	5.6.2	AT&T agrees not to modify, disassemble, decompile, reverse engineer, create derivative works of, or make any other attempt to discover or obtain the source code for
the Software. In the event any modifications are made to the Software by anyone other than Motricity or its authorized subcontractors, any and all warranties with respect to the Software and associated with such modifications shall immediately
terminate. 

  

	 	5.6.3	Unless expressly authorized by the other Party in writing, or unless otherwise specifically provided in this Agreement, neither AT&T norMotricity shall itself, nor
shall either authorize or assist any third party to, (a) remove, obscure, or alter any legal notices, including notices of Intellectual Property Rights present on or in the Content or Services provided hereunder or any other materials provided
by the other Party. 

  

	 	5.6.4	Motricity grants to AT&T’s OEM partners the Device Client licenses set forth in the Section 5.2 “OEM Support” of this Exhibit A-3.

  

	 	6.	Partner Integration Services 

Motricity will provide AT&T with partner integration services (e.g. integration with Yahoo! Search) as set forth within this Section
(“Partner Integration Services”). 
  

	 	6.1	Motricity will support partner integration services, subject to the Level of Effort to be mutually agreed upon by the Parties. 

 

	 	6.2	AT&T and Motricity will establish Level of Effort under a separate Service Request Form, pursuant to Section 10 of this Exhibit A-3. 

 

	 	7.	Web and/or WAP Services 

Motricity will provide AT&T with Web and/or WAP services (e.g. updates to new templates, application control, browser updates, etc.)
as set forth within this Section (“Web/WAP Services”). 
  

	 	7.1	Motricity will support Web/WAP Services, subject to the Level of Effort to be mutually agreed upon by the Parties. 

 

 12 

	 	7.2	AT&T and Motricity will establish Level of Effort under a separate Service Request Form, pursuant to Section 10 of this Exhibit A-3. 

 

	 	8.	Computer / Set-Top Client Services –Intentionally Omitted 

  

	 	9.	Continual Development and Custom Product – Intentionally Omitted 

 

	 	10.	Service Requests and Level of Effort 

Where AT&T requests Motricity to provide new or enhanced Service(s) that requires a determination of work effort to include scope,
schedule, resources and pricing (if any) (“Level of Effort”), AT&T will submit such Service Requests as described in the Service Request Process within the Service Agreement . 

 

	C.	Services. 

 Section 1. Current
Devices is deleted in its entirety and replaced with the following: 
  

	 	1.	Current Devices. Motricity will make the Services available on Devices. AT&T will provide Motricity a minimum of three Devices and up to four Devices
(subject to AT&T approval for each Device type for testing purposes at no charge to Motricity. In order to support Motricity maintaining a suitable testing environment for such Devices, AT&T will allow Motricity reasonable access to
AT&T’s wireless network for such testing. 

 Section 2. New Devices is deleted in its entirety and replaced
with the following: 
  

	 	A.	MEdia Net and Legacy Services. For Devices that support MEdia Net or Legacy Services, AT&T may request that the display of the Services made available in WML
and XHTML format conform to standards for devices and/or browsers in addition to those set forth above. When this occurs, AT&T shall deliver to Motricity a prototype device that is functional in all material respects, at no charge to Motricity.
Upon receipt of a prototype device that is functional in all material respects, and a Change Request from AT&T (as described in Exhibit D), Motricity will use commercially reasonable efforts to provide a written response to Cingular outlining
expected turn around time for device profiling and readiness for production support within ten (10) business days of such request. AT&T will provide to Motricity a minimum of four prototype devices that are functional in all material
respects for use by Motricity in connection with performing such services. Motricity will then profile the devices in a manner and on a schedule to be mutually agreed upon by the Parties at no additional cost to AT&T. 

Such devices shall have WAP browsers that adhere to industry specifications for either WML or XHTML (aka WAP 2.0). In the event that a
device does not have a browser that conforms to industry specifications, Motricity and AT&T will work together to determine how best to support the device within thirty (30) business days of Motricity learning that the device does not
conform to specifications. In some instances, Motricity will require AT&T to pay for additional work required to support the device service to AT&T’s satisfaction. In such event, Motricity will provide a written quote to AT&T in
response to such request within five (5) business days of coming to agreement on Motricity’s course of action to support the device. Upon AT&T’s acceptance of such quote, the Parties may enter into a mutually agreeable Work Order
for such services. In order to support Motricity maintaining a suitable testing environment for such devices, AT&T will allow Motricity reasonable access to Cingular’s wireless network for such testing. 

 

 13 

	 	2.	ATT.Net Service. For Devices that support the ATT.Net Service, the Parties will adhere to the Device Client Service process set forth within this Exhibit A-3.
AT&T will provide Motricity no less then three and up to four Devices (subject to AT&T approval) for each Device type for testing purposes at no charge to Motricity. In order to support Motricity maintaining a suitable testing environment
for such Devices, AT&T will allow Motricity reasonable access to AT&T’s wireless network for such testing. 

  

 14 

 B. EXHIBIT C-3 – COMMERCIAL TERMS FOR ATT.NET SERVICE 

 

	1.	Non Recurring Expense Fee or NRE Fee*** 

The non-recurring expense / one-time fee covers the purchase of hardware, installation, integration, project management and testing of Service (“NRE
Fees”) and will be paid pursuant to separate Statement of Works, Change Requests or Work Orders. 
 Motricity shall procure, operate and
maintain the hardware in support of the Service; with AT&T maintaining ownership of hardware. 
 *** 

 

	2.	ATT.Net Service Fee: 

 The Service
fees cover AT&T’s use of the Service that supports the ATT.Net Service (“ATT.Net Service Fees”). Motricity shall apply the ATT.Net Service Fees based on the total number of ATT.Net Active Users processed by Motricity with a given
calendar month. *** 
  

					
	 Tier
	  	Description	 	ATT.Net Service Fee
	 ***
	  	***	 	***
	 ***
	  	***	 	***
	 ***
	  	***	 	***
	 ***
	  	***	 	***

 A. The Parties further agree to the
following for the initial year of the ATT.Net Service: 
 *** 
  

	3.	Hosting Fees: 

 The Hosting fees
cover the people, space and power needed to host and operate the System (“Hosting Fees”). Motricity shall apply the Hosting Fees based on the total cumulative number of ATT.Net Portal Users being maintained by Motricity with a given
calendar month. *** 
  

					
	 Tier
	  	Description	 	Hosting Fee
	 ***
	  	***	 	***
	 ***
	  	***	 	***
	 ***
	  	***	 	***
	 ***
	  	***	 	***
	 ***
	  	***	 	***
	 ***
	  	***	 	***
	 ***
	  	***	 	***
	 ***
	  	***	 	***
	 ***
	  	***	 	***

 *** 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 15 

	A.	For purposes of clarity, in any calendar month where a MEdia Net portal user becomes an AT&T.Net Service Portal User, Motricity will apply the Hosting Fee set forth
above. 

  

	B.	Further, Motricity will ensure that AT&T is not being double billed on Hosting Fees under the MEdia Net and ATT.Net fee structure. In the event a Subscriber is
registered as both a Media Net portal user and an ATT.Net Portal User within a given calendar month, AT&T will be charged the Hosting Fees set forth in the above table. 

 

	C.	The Parties further agree to collaborate on a method and process for which Subscriber profiles would be purged from the respective databases for MEdia Net and ATT.Net
Service. 

  

	D.	*** upon six months’ prior written notice to Motricity, AT&T may elect to host the System and make the AT&T.Net Service (excluding certain Legacy Services
as described in Section B.1.b. of Exhibit A) available to Subscribers at AT&T’s expense at one or more facilities maintained by or on behalf of AT&T. AT&T acknowledges that its ability to host the Motricity Software and make the
AT&T Net Service available to Users may be subject to AT&T’s ability to obtain sufficient rights in certain third party technology (e.g., any third party software used in connection with the hosting, operation and/or maintenance of the
Services), content and applications. In the event that AT&T elects to host the Software, Motricity and AT&T shall enter into a mutually agreed upon license agreement prior to and as a condition of any transition of hosting to AT&T.

  

	4.	Incremental Hardware/Maintenance Fee(s):  

Upon the Parties’ determination that additional hardware is required beyond what is included within the NRE Fee above, Motricity shall provide firm
quote and if AT&T accepts such firm quote, then AT&T shall pay Motricity pursuant to a separate Work Order (“Incremental Hardware/Maintenance Fees”). For purposes of clarity the Incremental Hardware/Maintenance Fees includes
installation and integration of the incremental System components with the overall Service. All incremental hardware shall be supported by a detailed inventory. 
  

	5.	Partner Integration Service Fee 

The application of Web/WAP Service fees (if any) are as defined in Section 6 of this Exhibit A-3. 

 

	6.	Web/WAP Service Fees: 

 The
application of Web/WAP Service fees (if any) are as defined in Section 7 of this Exhibit A-3. 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 16 

 EXHIBIT G-2 – SERVICE LEVEL AGREEMENT – WEB BASED SERVICES SUPPLEMENT

 Appendix D of Exhibit G-2 is deleted in its entirety and replaced with the Revised Appendix D – SLA Monitoring Requirements set
forth below. 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 17 

 Appendix D – SLA Monitoring Requirements 

*** 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 18 

 A new Exhibit G-3 is hereby added to the Agreement and shall read as follows: 

EXHIBIT G-3 – SERVICE LEVEL AGREEMENT – ATT.NET SERVICES 

 

	1.	General Information 

  

	1.1.	Purpose 

 The purpose of this SLA is to
identify the levels of service that will be maintained by Motricity and to provide this information to operations personnel of both parties responsible for the monitoring and/or support of the Services. 

 

	1.2.	Scope 

 This Service Level Agreement
(“SLA”) describes the basic level of service that will be provided by Motricity in its support of the delivery of the Services to AT&T that enables and/or supports the ATT.Net Services. For purposes of clarity reference to Services in
this SLA means the ATT.Net Services. This SLA describes the requirements for the following: 
  

	 	a)	support and maintenance of all Motricity and third-party hardware and software for the Services 

 

	 	b)	7x24x365 support and response requirements for support calls; 

  

	 	c)	fixes, patches, and minor enhancements; 

  

	 	d)	new software releases that contain fixes to defects in production feature functionality; and 

 

	 	e)	resources to support acceptance testing, trouble shooting, and system upgrades. 

This SLA also defines requirements for response (including email, telephone, remote, and on-site) and resolution timeframes related to Severity 1,
Severity 2, and Severity 3 incidents, as well as non-performance financial penalties which will be owed to AT&T for failures to meet certain obligations defined herein. 

This SLA also defines expectations relating to: 
  

	 	•	 	 Motricity and AT&T Responsibilities with respect to the Services 

 

	 	•	 	 Service Performance Objectives 

  

	 	•	 	 Incident Management 

  

	 	•	 	 Incident Reporting Process 

  

	 	•	 	 Operational Reports 

  

	 	•	 	 Change Control Management 

This SLA should be used as a reference for AT&T’s Network Operations and its contracted affiliates and Motricity in support of the Services. It
provides the framework for surveillance, isolation, analysis, and resolution of problems related to the Services. 
 AT&T acknowledges that
Motricity’s provision of its Managed Service (including the availability of the System) may be impacted by the acts and/or omissions outside of Motricity’s “Span of Control” (defined below). To the extent Incidents arise during
the Term for reasons outside of Motricity’s Span of Control, Motricity shall not be liable for the Non Performance Compensation set forth within this SLA. 

For a complete list of the Services that are subject to this SLA, see the SLA Monitoring Requirements (Appendix D) below. 

 

 19 

	1.3.	Out of Scope 

 The following items are
deemed to be outside the scope of this SLA; however, both parties will make a good faith effort to establish the following independently from this SLA. *** 
  

	1.4.	Definitions  

 The terms used in
this SLA shall have their normal or common meaning, except that the following Capitalized terms shall have the following meaning for the purpose of this SLA. Additional definitions may be found within the Agreement and related Amendments.

  

			
	 Term
	  	 Definition

	ATT.Net Application Pages	  	ATT.Net Application Pages are portal pages within the ATT.Net Portal that render content wholly determined by the business logic of the particular application and are not
manageable by CPS Tools.
		
	ATT.Net Gateway	  	The ATT.Net Gateway is the set of transcoder servers hosted at Motricity that broker requests to and from the internet as well as the ATT.Net Portal and adapt web page content
for the Device Client. The ATT.Net Gateway has certain similar capabilities as the AT&T WAP Gateway such as service binding support and redirect capability.
		
	ATT.Net Sub- Category Pages	  	Each node on the Sub-Category Carousel can be associated with a specific Sub-Category page with feeds and content specific to that Sub-Category, e.g. Browsing to the
Entertainment Sub-Category Carousel and then clicking on Movies will take the user to the Movies Sub-Category page.
		
	ATT.Net Portal	  	The ATT.Net Portal is the set of mobile web / application pages that have the att.net-specific content and applications that have either been defined and/or published by
AT&T.
		
	ATT.Net Service	  	means the next generation wireless internet that will allow AT&T subscribers to easily find, consume and save global web content, to find people, places and things in the
local area and to browse and save popular editorial content. Further, the ATT.NET solution will also allow subscribers to have a consistent internet experience via a fully optimized HTML browser that enables interactivity, lower latency for a richer
internet experience.
		
	ATT.Net Shortcut Tiles	  	Shortcuts Tiles are added to a user’s web pane as quick links to content, either hosted on the portal or by a third party site. Shortcuts can be added by the user through
personalization, or by the AT&T content team as a default. Shortcuts can contain dynamic content as in the case of the My Teams tile or My Weather tile, but not necessarily. The tiles or quick links are represented as boxes with an icon image
and up to two lines of text.
		
	ATT.Net Sub-Category Carousel	  	Each Category on the Popular pane is associated with a Sub-Category Carousel specific to that category. This is a single multi-part page (similar to the Triptych page), which
contains multiple panes: one for each Sub-Category.

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 20 

			
	 Term
	  	 Definition

	ATT.Net Triptych Page	  	The ‘homepage’ of the ATT.Net Portal. The homepage is divided into 3 ‘panes’ (hence triptych) which are Web, Popular and Local. The current viewable pane can
be changed by moving the navigation to the left or right, but all three are delivered to the device as a single multi-part web page.
		
	Availability	  	*** Availability percentages shall be expressed to two decimal points with the second decimal place rounded up or down to the nearest one-hundredth of a percentage
point.
		
	Business Hours	  	Monday through Friday, 8:00 AM to 5:00 PM PST
		
	Busy Hour	  	Means the highest peak of transaction activity.
		
	Capacity	  	Means the transactions per second and concurrent usage as well as raw disk space of the System (measured in bytes) that is available to support the Service (in whole or in part).

		
	Motricity’s Span of Control	  	means Motricity’s facilities physical infrastructure (including external power sources), supporting network elements, web-to-the-Motricity network demarcation point, support
services, hardware and software associated with the Service that is under Motricity’s control (e.g. functionality that is provided by external vendors or suppliers with whom Motricity has a contractual relationship, including feeds from
providers of Motricity Sourced Content). This includes the System and its components for the transmission and control, security of network and data, physical security, software and user data including backup data; all hardware and software used in
connection with backing up data; and all Motricity employees and subcontractors participating in the provisioning of the Service. Motricity’s Span of Control does not include the services and systems that are under the control of AT&T or
its third party suppliers and service providers, including AT&T’s MMS Center and all other elements of the AT&T network nor does it include functionality or feeds from providers of content not under a contractual relationship with
Motricity.
		
	Commercial Launch	  	is defined as the date where the ATT.Net Service is to be made available to Subscribers for commercial use and is currently estimated to be on or around July 20,
2009.
		
	Device	  	means the AT&T designated mobile device(s) that are certified or will be certified for use on the AT&T network in support of the AT&T commercial service offering
(e.g.,ATT.Net Service, MEdia Net Service, etc.)
		
	Device Client	  	Means the Software that conforms to a specific Device or set of Devices.
		
	Down Time	  	***
		
	Emergency Maintenance	  	Maintenance required outside the agreed-upon Scheduled Maintenance or necessary within Scheduled Maintenance but not scheduled in advance pursuant to Section 6.
		
	Hours of Operation	  	24 hours a day, 7 days a week and 365 days a year.

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 21 

			
	 Term
	  	 Definition

	Incident	  	Any problem with the Service for which AT&T Mobility requests support in conformance with this SLA. Any impact, regardless of how minor, to AT&T Mobility subscriber s
will be considered as an outage/incident and Incident Management Process will be initiated.
		
	Incident Management Process	  	This facilitates incident management through the notification and escalation processes. This process alerts designated AT&T Mobility departments to Service-affecting
incidents and provides a method by which succeeding levels of technical expertise and related management are engaged in restoration activities.
		
	Latency	  	The time that elapses between an event and the response to that event.
		
	Operational	  	The Service or any component thereof is (i) functional and available to its intended subscriber in full accordance with its documentation and all applicable specifications, and
(ii) not experiencing any subscriber -impacting errors, Defects or service-limiting issues outside of those that are noted in release notes for the production version which may be resolved in subsequent releases as mutually-agreed upon by AT&T
and Motricity.
		
	Resolution	  	The permanent correction of the error, Defect or condition giving rise to the Incident/outage or a mutually agreed upon work-around.
		
	Root Cause Analysis	  	The process of identifying the core events that resulted in failure to meet performance requirements.
		
	Scheduled Down Time	  	***
		
	Scheduled Maintenance	  	***
		
	Service Impact Report (“SIR”)	  	The severity level assigned to an Incident based on the Incident classifications defined in section 4.1.3 below. SIR reflects the degree of Subscriber impact resulting from an
incident, with an SIR 1 having the greatest impact and a SIR 3 having the least.
		
	Subscriber	  	means a unique AT&T end user of the ATT.Net Service, MEdia Net Service or Legacy Services as authenticated by Motricity and depending upon the context.
		
	System	  	Means the AT&T Property and any or all platforms, databases, software, Product and API(s), provided by, or on behalf of, Motricity that supports the ATT.Net
Service.
		
	Technical Bridge	  	A teleconference that brings together appropriate technical people and their immediate supervisors and managers to focus on isolating and resolving an Incident.
		
	Technical Control Bridge	  	A teleconference used by higher-level managers or executives who need to understand what has occurred, the progress made toward Incident Resolution and whether or not additional
resources are needed to resolve the Incident.

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 22 

			
	 Term
	  	 Definition

	Third Party Site(s)	  	Means a website(s) that is(are) external to AT&T or Motricity and interacts with the Service such as Facebook, MySpace, etc.
		
	Total Time	  	The total number of minutes in a given calendar month.
		
	Total Monthly Fees	  	***
		
	TPS	  	Transactions Per Second
		
	Trouble Ticket	  	A numbered record that documents a significant event or Incident. The tracking document for an Incident or Scheduled Maintenance.

 

	2.	Responsibilities and Services 

 This
Section 2 describes Motricity’s support responsibilities with respect to the Services and the corresponding responsibilities of AT&T. 
  

	2.1.	Motricity Responsibilities 

 Motricity
will provide day-to-day service operations, maintenance and administration in support of the Services that are within Motricity’s Span of Control, as described below. 

It is the intention of Motricity to expeditiously remedy incidents that have been identified either internally by Motricity or AT&T. Corrective
action by Motricity assumes that the incident is within its Span of Control and AT&T has provided all relevant information, if available, to Motricity. See the section entitled Mandatory Information for Incident Reporting for required reporting
information. 
 Motricity will pursue the resolution of an incident with outside vendors provided Motricity has a contractual arrangement with
the vendor. During the resolution period, Motricity will issue updates to AT&T pursuant to the severity of the incident, as described later in this SLA. 

Any third party content provider contracted directly by AT&T is not a party to this agreement. Any loss of content from such providers is outside of
Motricity’s Span of Control. 
  

	2.2.	Motricity Carrier Care 

 The Motricity
Carrier Care Support Services team is an interface between AT&T’s Level 2 Support Group (AT&T’s non-customer facing group) and Motricity for support of services provided by Motricity. This arrangement provides AT&T with access
to a single point of contact for reporting incidents, receiving updates and escalation. Table 1 provides the Motricity Carrier Care hours of operation and contact information. A complete list of all contacts is also shown in Appendix A. These
contacts are to be contacted per the escalation procedures outlined in Section 4.1.5. 
  

			
	Hours of Operation	  	24 hours a day, 7 days a week and 365 days a year (7/24/365)
		
	Contact Phone Number	  	***
		
	Email Address	  	***

 Table 1, Motricity Carrier Care Contact Information

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 23 

	2.2.1.	Motricity Support Services 

The following list identifies services that are offered by Motricity Support Services to AT&T: 

 

	 	•	 	 Telephone and email support for incident resolution 

  

	 	•	 	 Advisory Bulletins 

  

	 	•	 	 Notification of planned maintenance activities 

  

	 	•	 	 Post Mortem Reports for Severity 1 (SEV1) and recurring incidents classified as Severity 2 (Sev2) including a Root Cause Analysis (RCA) upon request.
Initial Reports are delivered within 24 hours of resolution with a complete Post Mortem report within three (3) business days. 

  

	2.3.	AT&T Responsibilities 

 AT&T will
provide support for Incident Management as detailed in Section 4. 
  

	3.	Service Performance Objectives 

  

	3.1	Service Availability 

 Service
Availability (SA) is defined as the amount of time the service is up excluding planned Maintenance and AT&T caused outages, computed as: 

*** 
 The above calculations allow a weighting
for partial outages and degraded service, such that only the fraction of Users denied service contributes to negative Service Availability. 
  

	3.1.1	Service Availability Target  

Effective as of Commercial Launch, Availability will start at *** Motricity shall provide an overall System service availability of *** for all Services
listed in the SLA Monitoring Requirements (Appendix D) below, measured at no less than the frequency shown in Appendix D and reported at monthly intervals as described in Section 6.2 below. This measurement excludes downtimes caused by AT&T
and service interruptions due to planned maintenance approved in advance by AT&T. 
  

	3.2	Service Latency 

 User requests for
Services shall be fulfilled in accordance with Table 2 below for each calendar month. This includes delivery of all bytes of the response (content plus protocol overhead) that Motricity controls (i.e. service requests and subsequent requests for
which the browser’s URL target is hosted by Motricity). 
 Motricity will achieve the latency targets set forth in Table 2 below/. The
parties agree to review actual performance results compared to latency targets on or before September 30, 2009 to determine whether or not new targets are required. 

Prior to the end of the first period, parties will agree to either amend the existing latency targets, or agree to keep them as is. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 24 

 In addition to the monthly SLA reports, Motricity will provide an analysis of capacity and performance,
system dimensioning (including maximum, sustainable, peak transactions per second, per hour, peak sessions per hour,) and actual traffic information (including average and peak latency, average http transaction payload, etc.) for the Services (by
Service type) as input into any and all performance reviews. 
 Thereafter, latency shall be reviewed from time-to-time during the Term and to
assess whether the latency targets need to be adjusted due to increased volumes, or new functionality that elongates the transaction time. Unless otherwise mutually agreed, these are the targets for penalties as set forth in Section 8.3.

  

											
	 	  	 	  	***	  	 	  	 	  	 

 Table 2, Latency Target Ramp 

These requirements are specific to the portion of end to end Latency incurred within Motricity’s Span of Control and will be measured from the
network equipment at Motricity that first receives and processes a Service request from the AT&T network and transmits a response back. The design of latency monitoring infrastructure will ensure appropriate components of the request and
response are adequately measured. The implementation of latency monitoring infrastructure will include the deployment of a separate and specific server(s) for the purpose of monitoring and fault management. The latency introduced by the GPRS
network, the WAP Gateway and other elements of the AT&T Network are excluded from the latency measurements described above. 
 3.3
Intentionally Omitted 
 3.4 *** 

3.5 Third-Party Content Providers  

Motricity will be responsible for the performance, service availability and service latency of all providers of Motricity Sourced Content with whom
Motricity has a contract. Where such content provider contracts exist, Motricity will perform appropriate alarming, monitoring and fault management to ensure that performance of these providers fully supports the service objectives defined in this
SLA. Motricity will also identify those content providers to AT&T and provide notification of changes to such contractual relationships no less than 30 days in advance of such changes becoming effective. 

Expectations for processing of third party content feeds as set forth in Appendix D are as follows: For streaming content (sports scores and stock
quotes), all received content must be processed and published a maximum of *** For all other content feeds that are updated at least once a day, content must be processed and published within a maximum *** For all other content feeds (those updated
less frequently than once per day), the content must be processed and published as soon as possible, and will at all times display content for the current day. 

Motricity will also provide monthly reporting of service interruptions, availability measures and other data for contracted providers of Motricity
Sourced Content in accordance with Section 6. 
 In addition, Motricity will be responsible for all degradations and service impacting
issues affecting the Services that are caused by providers of Motricity Sourced Content from a Motricity SLA performance perspective. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 25 

	4.	Incident Management 

  

	4.1.	Incident Resolution Responsibilities 

Incident resolution requires teamwork between Motricity and AT&T. A key element in this teamwork approach is AT&T’s understanding of the User
service(s) offered by Motricity. 
 All AT&T identified incidents concerning failures of the Services that cannot be solved by AT&T
representatives will be reported to Motricity Carrier Care Support Services, pursuant to the Reporting Process procedures outlined below. AT&T will assign a Severity Level per Table 4. If Motricity disagrees with the Severity assignment, both
parties will negotiate in good faith after the resolution of the incident but all restoration will proceed based upon AT&T’s initial Severity assignment. 

Any reported incident that is caused by a failure that is outside Motricity’s Span of Control and not directly related to its delivery of a
subscriber service will be returned to AT&T with an appropriate explanation. Should Motricity determine that an incident being worked by Motricity Carrier Care Support Services is within AT&T’s control, the incident will be closed and
returned to AT&T for proper resolution. 
  

	4.1.1.	AT&T Contact Information 

 In order
for Motricity Carrier Care to effectively resolve Incidents, it is necessary for Motricity to have an accurate list of AT&T’s designated key personnel. This information will be exchanged between the two parties and updated as changes
warrant. Appendix A shows the type of contact information required, showing the current contacts at the Third Amendment Effective Date. This data will be maintained and updated by the two parties outside of this SLA. 

 

							
	 AT&T
	  	 Hours of Operation
	  	 Role
	  	 Phone/Email

	Mobility National Operations Center (MNOC)	  	24 x 7 x 365	  	Incident Management and Emergency Maintenance	  	***
				
	MMS External Partner Ops	  	8:00 am – 5:00 pm PT Monday – Friday	  	Incident Root Cause Analysis, Change Management, Performance Reports and Tier 2 Support	  	***
				
	Change Management	  	8:00 am – 5:00 pm PT Monday – Friday	  	Maintenance Notification – all maintenance	  	***

 Table 3, AT&T Contact Information 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 26 

	4.1.2.	AT&T Responsibilities 

 The following
section identifies the responsibilities of AT&T as it relates to this SLA. 
  

	4.1.2.1.	General Responsibilities 

  

	 	•	 	 Acts as the primary and direct contact with the User. 

 

	 	•	 	 Answers simple questions and resolves minor issues such as resetting passwords or creating new User accounts. 

 

	4.1.2.2.	Incident Responsibilities 

  

	 	•	 	 Creates a trouble ticket that clearly states the problem after gathering all pertinent information about the incident including name, User number,
password and any other additional information that is important to resolution of the incident. 

  

	 	•	 	 Records any subsequent conversation with the User relative to the incident in the same trouble ticket. 

 

	 	•	 	 “Owns” the resolution of an incident by coordinating its resolution within AT&T operational and technical environment and with Motricity
or its designees. 

  

	 	•	 	 Resolves the incident with the User or determines that the capability is outside the scope of current functionality. 

 

	 	•	 	 Explains the resolution of the incident to a technical peer or is capable of targeting the root technical problem for resolution.

  

	 	•	 	 Describes the incident in technical terms to an engineer or developer who is responsible for resolution of the incident. 

 

	 	•	 	 Explains the resolution of particular escalated trouble tickets to AT&T’s internal staff members when such an explanation may have the
potential for reducing the volume and categories of escalated trouble tickets. 

  

	4.1.2.3.	Service Responsibilities 

  

	 	•	 	 Uses and understands all Motricity service features that are available to the User. 

 

	4.1.2.4.	Technical Responsibilities 

  

	 	•	 	 Understands and is knowledgeable about problems that may arise during service usage. 

 

	 	•	 	 Understands and is knowledgeable with respect to functionality of supported handset models. 

 

	 	•	 	 Understands and is knowledgeable with email notification systems, the Internet and the World Wide Web. 

 

	 	•	 	 Understands and is knowledgeable with its network operations and is capable of discerning whether an incident is internal to its internal operations
before identifying the incident as a trouble ticket for Motricity. 

  

	4.1.3.	Incident Handling and Updates 

 The
Motricity Carrier Care Support Services group of Motricity will coordinate incident isolation, testing and repair work within Motricity and all contracted third party systems that are within Motricity’s Span of Control. During the incident
isolation and troubleshooting process, Motricity Carrier Care Support Services will communicate incident resolution progress with AT&T based upon the times specified in Table 4. Additionally,

  

 27 

 
Motricity Carrier Care Support Services will proactively inform AT&T when an issue or condition arises that may cause potential system anomalies and be a potential source for the creation
trouble tickets. 
  

							
	 Motricity Incident
Level
	  	 Description
	  	 Update
Method
	  	 Update

Objectives

	 Severity 1

(Sev1)

AT&T SIR1
	  	 Severity 1 problems are conditions that render the service inoperative and the inability to use the service has a critical effect on
operations. The condition is generally characterized by complete system failure and requires immediate restoration. Examples of this incident level being attained include:

 
 •   A complete outage of
critical service(s)
  

•   Loss of service or functionality feature that affects *** or more of
subscribers
  

•   A recurring anomaly impacting critical service(s).

 
 •   Inability to
provision a service.
  

•   Device Client functionality is inoperative; inability to use has a critical impact on
Subscriber.
	  	Email and phone	  	 First response within ***
  

First Update within ***
  

Subsequent updates ***, or upon change in status.
  

Motricity will update AT&T with the information outlined in Appendix C.

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 28 

							
	 Severity 2

(Sev2)

AT&T SIR2
	  	 Severity 2 problems are conditions under which the service is partially inoperative, but is still usable. The inoperative portion of
the service restricts operations but has a less critical effect than a Severity 1 condition. Examples of this incident level being attained include:
  

•   Loss of service and/or functionality that affects *** of the subscribers.

 
 •   Loss of the ability
to utilize some aspect of product features or functionality.
  

•   Device Client is partially inoperative and is considered as severely restrictive by
Subscriber.
	  	Email or phone	  	 First response within ***
  

First update within ***
  

Subsequent updates every *** or upon change in status.
  

Motricity will update AT&T with the information outlined in Appendix C.

				
	 Severity 3

(Sev3)

AT&T SIR3
	  	 Severity 3 problems are generally non-service affecting conditions under which the service is usable and either has no material
affect on operations or has very limited affect on operations. The condition is not critical to overall operations, and does not severely restrict such operations. Examples of this incident level being attained include:

 
 •   A minor degradation
of the service that affects *** of the subscribers.
  

•   Non-service impacting intermittent system faults.

 
 •   Loss of resources /
capacity / traffic measurement function.
  

•   Loss of reporting functionality.

 
 •   Invalid measurement
data.
	  	Email	  	 First response within ***
  

First update within ***
  

Subsequent updates *** as agreed between the two parties.
  

Motricity will update AT&T with the information outlined in Appendix C.

Table 4, Incident Handling Notification Timetable 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission

  

 29 

	4.1.4.	Technical Bridge and Executive Bridge 

During the resolution of a service affecting incident, AT&T may establish a Technical Bridge and/or an Executive Bridge for any Incident. Motricity
shall join the Technical Bridge upon *** from AT&T for Severity 1 issues as noted in Table 5 below. These bridges are used for NOC-to-NOC communication, troubleshooting, triage and escalation. Unless otherwise notified by AT&T, a Technical
Bridge or Executive Bridge will be established as follows: 
  

							
	 Action
	  	 Sev 1
	  	 Sev 2
	  	 Sev 3

	 Technical Bridge
	  	*** when reasonably possible)	  	***(or sooner upon request from AT&T)	  	***(or sooner upon request from AT&T)
				
	 Executive Bridge
	  	***	  	***	  	N/A

 Table 5, Timelines for Technical and Executive Bridges

  

	4.1.5.	Escalation Procedures 

  

	4.1.5.1.	Motricity Internal Escalation 

Escalation procedures are in place at Motricity to manage the resolution of incidents when they occur. If a Severity 1 (Sev1) incident is
not resolved within *** Motricity was made aware of the problem, the incident will be escalated within Motricity to the dedicated Manager of Service Operations, who will drive escalation and resolution of the incident within Motricity’s
Operations and Engineering groups, and ensure that AT&T is kept updated with the incident resolution process. The appropriate Business Development person will also be informed of the occurrence and status of any Sev1 incident. 

If the Sev1 incident has not been resolved by the Motricity & AT&T NOC teams within ***, the Director of Commercial Operations will become
directly involved with driving the incident to resolution and communicating with the appropriate AT&T personnel. The status of the incident will also be communicated to senior management within Motricity. 

 

	4.1.5.2.	AT&T Escalation to Motricity 

 In the
event that Motricity does not respond to AT&T within the times shown in Table 4, AT&T can request that the incident be escalated to the next level, based on the contact information shared between the two companies (see Appendix A for a list
of names that are current as of time of the Effective Date). All escalation requests must be initiated through the 7x24 contact information provided in Table 1, and not to the individual directly. Only in the event that the 7x24 representative does
not escalate within *** of AT&T’s request, should the appropriate Motricity individual be contacted directly. AT&T must verify that escalation has not taken place prior to calling any Motricity employee directly. 

For the purposes of clarification, Table 6 provides escalation timelines for Severity 1 and 2 incidents, based on time after the incident was reported.
Severity 3 incidents seldom require escalation but in the event that AT&T believes that Motricity is not addressing the incident in a timely manner, the parties can mutually agree to elevate the priority of the incident, and treat it as a
Severity 2 incident. 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 30 

							
	 Escalation Level
	  	 Escalation Contact
	  	Severity 1	 	Severity 2
	 Level 1
	  	Carrier Specialist	  	***	 	***
				
	 Level 2
	  	Manager – Service Operations	  	***	 	***
				
	 Level 3
	  	Director – Commercial Operations	  	***	 	***

 Table 6, Escalation Timetable 

 

	4.1.5.3.	Additional Escalation Information 

Motricity and AT&T will ensure that any additional processes that are required to ensure the smooth escalation of incidents within each organization
are clearly communicated to one another in writing, so that the escalation processes within each organization and between the two organizations are clearly understood by both parties. 

Motricity and AT&T will exchange the names and contact information of the personnel who need to be kept informed of progress during the escalation
process in Appendix A. Both parties are responsible for ensuring that the contact information is updated and exchanged when circumstances warrant. This information will not be updated and kept current as part of this SLA, but will need to be
maintained separately by the two parties outside of this SLA. 
  

	4.2.	Mobile Web Handsets for Incident and Problem Management 

In order for Motricity to provide the most effective level of support, AT&T agrees to provide Motricity with two (2) testing units for each
device type (touch, and non-touch) specifically for supporting Incident and Problem Management. Each such device shall be appropriately provisioned and have a valid account and password as to properly access the AT&T network. Each such unit
shall be the GA (general availability) version of the handset and should be supplied to Motricity no less than 30 days prior to launch. 
  

	5.	Incident Reporting Process 

  

	5.1.	Communicating Incidents 

 AT&T will
communicate incidents to Motricity in the following manner: 
  

	 	•	 	 Phone call to Motricity SOC or sends a trouble ticket to Motricity via email using the email address of *** 

 

	 	•	 	 Motricity sets the initial classification of their internal trouble ticket according to the AT&T notification (see “Mandatory
Information” below), unless otherwise agreed between Motricity and AT&T. 

  

	 	•	 	 Motricity will generate a single response for each trouble ticket that is received from AT&T, to confirm receipt of the incident report.

  

	5.1.1.	Mandatory Information for Incident Reporting 

For each AT&T originated incident, AT&T will make every effort to provide as much information to Motricity that will facilitate timely problem
determination and resolution. Upon notification of the incidents, the required information will be verified. When Motricity has received sufficient information, Motricity will begin resolving the incident and provide feedback to AT&T as
described above in Section 5.1 Communicating Incidents. 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 31 

 AT&T will use best efforts to provide Motricity the following information via email for all reported
incidents as required: 
  

	 	•	 	 Reference number assigned by AT&T. 

  

	 	•	 	 Motricity Service being used. 

  

	 	•	 	 System Identity number (usually phone number). 

  

	 	•	 	 Time and date of the transaction in question. 

  

	 	•	 	 Description of the incident. 

  

	 	•	 	 Severity of the incident or problem. 

  

	 	•	 	 List of specific steps to reproduce the problem if possible 

 

	 	•	 	 List of those actions taken by AT&T to verify the problem and that AT&T has attempted to resolve the incident. 

 

	 	•	 	 Other comments to provide additional information as needed. 

 

	 	•	 	 All communications that include references to time should be expressed using a 24-hour clock format and should always utilize and reference PST as the
standard time zone. 

  

	6.	Motricity Reports 

  

	6.1.	Post Mortem Reports 

 The purpose of the
Post-Mortem Report is to outline the known information regarding the incident and possible root causes and to summarize the incident resolution timeline. If known, it will also identify corrective actions to prevent its reoccurrence. Motricity will
create a Post-Mortem Report and provide such report to AT&T per Section 2.2.1. 
  

	6.2.	Service Level Reporting 

 Each month,
Motricity will provide AT&T with a “Monthly Service Level Report” indicating the service performance for the Services for the previous month (see SLA Monitoring Requirements (Appendix D) below for detailed list of Services associated
with this SLA). This report will contain performance reporting for the service performance objectives listed in Appendix D and a summary of the weekly incident response reports described in Section 6.3 for such month. 

Motricity shall supply the Monthly Service Level Report no later than the tenth business day of the month following the immediately preceding month. It
is agreed that Motricity will work towards publishing the Monthly Service Level Report on the sixth business day starting 6 months from the initial launch of Services. 

The Monthly Service Level Report shall include, among other things, the following information related to service availability for the Services listed in
Appendix D: 
  

	 	•	 	 Total minutes in the current month 

  

	 	•	 	 Total available minutes for the reported month for each Service 

 

	 	•	 	 Calculated Service Availability, presented as a percentage for each Service 

 

	 	•	 	 Target Service Level Availability for each Service 

 

 32 

	 	•	 	 Variance from Target Service Level for each Service 

  

	 	•	 	 Overall Service Level Availability for the Services 

The Monthly Service Level Report shall include, among other things, the following information related to latency for the Services listed in Appendix D:

 *** 
 The Monthly Service Level
Report shall also include, among other things, the following information for the Services listed in Appendix D: 
  

	 	•	 	 Appropriate performance metrics related to processing of
3rd party content feeds 

 

	 	•	 	 Overall Service Level Availability for Motricity contracted Third Party Content Providers 

 

	 	•	 	 Detailed log of all service impacting incidents for the month 

 

	6.3.	Open Issues List Reporting 

 Motricity
shall provide a weekly Open Issues Report, to be reviewed jointly with AT&T during the weekly Operations Call. Both parties agree to periodically review the appropriateness of the frequency of the Open Issues Report and Operations Call. This
report shall include the following information: 
  

	 	•	 	 Outage report including; 

  

	 	•	 	 Ticket Number 

  

	 	•	 	 Start time 

  

	 	•	 	 End time 

  

	 	•	 	 Resolution 

  

	 	•	 	 Severity level 

  

	 	•	 	 Impact 

  

	 	•	 	 Number of Reported Issues and brief summary of the issues 

 

	 	•	 	 Date that each Reported Issue was opened 

  

	 	•	 	 Current Reported Issue status, and if resolved, the date of the resolution. 

 

	 	•	 	 Total number and description of unresolved issues. 

  

	7.	Change Control Management (CCM) 

  

	7.1.	Planned Maintenance by Motricity 

Motricity will ensure that any planned maintenance events under its Span of Control will be executed in a well-coordinated manner. Proper execution
includes notification to AT&T by Motricity Carrier Care Support Services. 
  

	7.1.1.	Service Interruptions and Advanced Notification Requirements 

Motricity will provide AT&T with *** advance notice (via email) of all planned maintenance activities resulting or potentially resulting in service
interruptions that will have a direct impact on the Services unless otherwise mutually agreed by the parties. Motricity may assume that AT&T accepts the scheduled maintenance unless Motricity is advised via email within *** prior to the time of
the planned event. 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 33 

 Unless otherwise arranged, Motricity will perform planned service interruptions from *** (the “AT&T
Maintenance Window”) or as otherwise communicated between the two parties. Notwithstanding the foregoing, upon AT&T’s sole discretion, the AT&T Maintenance Window may be extended to allow for maintenance, testing and/or validation
of the Services that falls outside of the AT&T Maintenance Window 
 *** 

Please Note: *** Any Motricity unplanned system downtime resulting from a AT&T maintenance activity or otherwise required on account of
AT&T’s action(s) or inaction(s), will not be counted against the Motricity SLA service measures from the time the requested maintenance activity was scheduled through the end of that month. The outage and/or service degradation must be
directly attributable to the AT&T maintenance activities or otherwise required on account of AT&T’s action(s) or inaction(s). 
  

	7.1.2.	Communications Related to Planned Maintenance 

Motricity notification of planned maintenance will be communicated to AT&T through use of the Maintenance Request Worksheet shown in Appendix B.
Motricity will provide official notification to AT&T of the start and end of a planned maintenance activity via email to the contacts identified in Section 4.1.1. During all planned maintenance activities, AT&T will establish a
technical bridge for real time communication of status and progress, and Motricity will participate in that technical bridge unless otherwise agreed by both parties. 
  

	7.1.3.	Canceling Planned Service Interruptions 

In the event of an AT&T emergency, AT&T may cancel the planned service interruption. Cancellation by AT&T may occur only if AT&T notifies
Motricity within one (1) business day of the scheduled start time of the maintenance window. Any notification of cancellation must come directly from either an Operations Manager or AT&T Team Leader via voice notification by calling
866-459-4636 (425-638-8700 for local or International calls), with a follow-up email that should be sent to: 
 ***

  

	7.1.4.	Restrictions Associated with AT&T’s Cancellation 

In the event that AT&T cancels a maintenance activity planned by Motricity, as defined in Section 7.1.1 above, and the parties are unable to
mutually agree on an alternative schedule, Motricity will not be held to the SLA service measures from the time the requested maintenance activity was scheduled through the end of that month. The outage and/or service degradation must be directly
attributable to the postponed maintenance activities. 
 If an alternative schedule is agreed upon, but a failure occurs between the originally
approved maintenance window and the rescheduled maintenance window, Motricity will not be held to the SLA services measures for that related outage and/or degradation. 
  

	7.1.5.	Planned Service Interruptions by AT&T 

AT&T will provide Motricity with advance notice (via email to *** of all planned maintenance activities requiring support from Motricity. AT&T
will make every effort to provide five (5) business days advance notice and will provide at a minimum two (2) business days advance notice of such activities. Such planned activities will exclude changes to Motricity software and/or
configurations as these would require additional notice. 
  

	7.1.6.	Unplanned Service Interruptions by AT&T 

AT&T will notify Motricity of any unplanned service interruptions via email to Motricity Carrier Care (*** as quickly as is reasonably possible for
AT&T. 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 34 

 Motricity will make all reasonable efforts to support AT&T in resolving the issue. Motricity may charge
its standard professional services fees for such efforts. 
  

	7.1.7.	Splash Page During Maintenance 

 The
parties will cooperate to display a “splash page” during any planned or emergency maintenance that would otherwise result in a TCP timeout from a WAP Gateway and other mutually agreed required maintenance activities requiring customer
requests to be blocked whenever reasonably technically feasible. Such a page will be presented to users of both the wired and wireless web access points, to inform them of temporary unavailability of the Services. Service of the splash page does not
constitute availability, but is categorized as either planned or unscheduled service interruption (in accordance with Section 7.1). AT&T will provide the static WML/xHTML content to be displayed in the “splash page”. 

 

	7.2.	Capacity Planning Forecasts 

 To ensure
the highest level of service, Motricity requires AT&T at least twice per year to provide a forecast estimating the growth of their customer base (3, 6, 9 and 12 months into the future) and likely service usage. This will allow Motricity to plan
the required resources to support the services for AT&T’s customers. If AT&T becomes aware of any material changes that would impact any forecast previously provided to Motricity (e.g., if AT&T has a special promotion plan in which
a high number of new customers are anticipated), Motricity must be given 30 days advance notice of any change in the forecast to prepare for such additional capacity. If AT&T fails to provide Motricity with such notice, Motricity will not be
held responsible for any failures to the performance objectives that could have been avoided had Motricity received such notice. A forecast provided pursuant to this section is only a forecast and is not a commitment on behalf of AT&T for the
forecasted amount. 
  

	8.	Financial Consequences of Non-Performance 

  

	8.1.	Financial Consequences for Failure to Meet Service Objectives 

The following sections define financial penalties for non-performance related to service objectives within the Motricity Span of Control. 

These non-performance penalties set forth in this Section 8 will apply commencing on the date of commercial launch of the Services, unless the
parties agree in writing to delay the application of non-performance of penalties for a particular Service or Services. The total financial penalties owed to AT&T under the Agreement will be subject to the SLA penalty cap set forth in Table 7
below. For purposes of clarity the SLA penalty cap under this Exhibit G-2 is in addition to any other SLA exhibit. 
  

							
	 	 	 	  	***	  	 

 Table 7, Penalty Cap Phase-In Schedule 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 35 

 For the purposes of the SLA, Motricity “Total Revenue” shall be calculated as follows: *** For
further detail regarding the non-performance penalties described below, reference SLA Penalty Calculation Model (Appendix E) below. SLA Penalty Cap means the percentage of Total Revenue for the month. 

For any month for which there is an Availability and a Latency penalty due for the same period of time, Motricity shall be required to pay only the
Availability penalty and the Latency penalty shall be waived when mutually agreed that there was a common or related cause. 
 Motricity will
deduct penalties for non-performance from the subsequent month’s invoice to AT&T for the Services. 
  

	8.2.	Service Availability 

  

	(a)	Service availability targets apply to Services provided to AT&T as described in the SLA Monitoring Requirements (Appendix D) below and will be reported as required
in Section 6 above. 

  

			
	 	  	***

Table 8, Service Availability Penalty Calculation 
  

	(b)	Subject to Section 8.1, Motricity agrees to pay to AT&T service availability failure fees computed on a monthly basis, as a calculation of (i) plus (ii):

 *** 
 Motricity will
utilize the most recent and relevant historical user data available for the purpose of determining the percentage of users impacted during periods of unavailability. 
  

	8.3.	Service Latency 

 Service latency targets
apply to Services provided to AT&T as described in Appendix D and will be reported as required in Section 6 above. Notwithstanding the foregoing, non-performance penalties will apply solely to the following portions of the Services as
further described in Appendix D: 
  

					
	 	  	***	  	 

 Table 9, Latency Penalty Calculation 

Subject to Section 8.1, Motricity agrees to pay to AT&T excessive latency fees based on performance according to Table 9 above for each month of
the SLA reporting period. In the event the monthly latency measurement for a particular Service Area listed in Table 2 above *** 
  

	8.4	*** 

  

	8.5	*** 

  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 36 

  

	9.	Right to Terminate 

  

	(a)	Right to Terminate for Failure to Meet Monthly Service Availability Requirement. 

In the event that the monthly service availability target described in Section 3.1 is not met for the Service Areas listed in
Section 8.2 above in any three calendar months within any four month period during the Term, then, at the end of any such third failed month, AT&T shall have the right, in its sole discretion, to terminate the Agreement for cause upon
thirty (30) days prior written notice to Motricity or to provide Motricity notice of AT&T’s intent to develop a “Get Well Plan.” In the event that AT&T delivers a “Get Well Plan” notice, the parties will use
good faith efforts to agree to and execute on a plan for Motricity to remedy the applicable performance failures and meet the service availability target set forth in Section 3.1. Upon implementation of any such mutually agreed plan, a new four
month measurement period to determine compliance with the service availability requirement will commence. 
  

	(b)	Right to Terminate for Failure to Meet Latency Requirement. 

In the event that the latency requirement described in Section 3.2 is not met for the Service Areas listed in Section 8.3 above
in any three calendar months within any four month period, then, at the end of any such third failed month, AT&T shall have the right, in its sole discretion, to terminate the Agreement for cause upon thirty (30) days prior written notice
to Motricity or to provide Motricity notice of AT&T’s intent to develop a “Get Well Plan.” In the event that AT&T delivers a “Get Well Plan” notice, the parties will use good faith efforts to agree to and execute on
a plan for Motricity to remedy the applicable performance failures and meet the service latency target set forth in Section 3.2. Upon implementation of any such mutually agreed plan, a new four month measurement period to determine compliance
with the service availability requirement will commence. 
 Appendix A – Contact & Escalation List

 Both parties are responsible for ensuring that the contact information is updated and exchanged when circumstances warrant. This
information will not be updated and kept current as part of this SLA, but will need to be maintained separately by the two parties outside of this SLA. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 37 

 Motricity Customer Care Contact Information 

 

			
	 Primary Contact (Single Point of Contact) 24 X 7

	Contact Name	  	Service Operations Center (SOC) / Carrier Care
	Title	  	N/A
	Phone	  	***
	Email	  	***
	
	 Level 1 Escalation

	Contact Name	  	***
	Title	  	Manager, Service Operations
	Phone	  	***
	Email	  	***
	
	 Level 2 Escalation

	Contact Name	  	***
	Title	  	Director, Commercial Operations
	Phone	  	***
	Email	  	***
	
	 Level 3 Escalation

	Contact Name	  	***
	Title	  	Sr. Director - Systems & Network Operations
	Phone	  	***
	Email	  	***

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 38 

 AT&T Contact Information 

 

							
	 AT&T
	  	 Hours of Operation
	  	 Role
	  	 Phone/Email

	Mobility National Operations Center	  	24 x 7 x 365	  	Incident Management and Emergency Maintenance	  	***
				
	MMS External Partner Ops	  	 8:00 am – 5:00 pm PT

Monday – Friday
	  	Incident Root Cause Analysis, Change Management, Performance Reports and Tier 2 Support	  	***
				
	Change Management	  	 8:00 am – 5:00 pm PT

Monday – Friday
	  	Maintenance Notification – all maintenance	  	***

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 39 

 Appendix B – Maintenance Request Worksheet 

This Maintenance Request Worksheet is be sent to: *** and *** 
  

	1)	Title of Maintenance 

  

	2)	Brief Description of Maintenance 

  

	 	•	 	 Scope and full description 

  

	 	•	 	 AT&T service 

  

	3)	Maintenance Start Date & Time 

  

	4)	Maintenance End Date & Time 

  

	5)	AT&T Service Impact 

  

	 	•	 	 Impact to AT&T internal & external customers 

 

	 	•	 	 Explanation of Information Service unavailability 

  

	6)	Information Service Impact Assessment (within the scheduled window) 

  

	 	•	 	 Duration in minutes 

  

	 	•	 	 Estimated start/end time of AT&T service impact 

  

	7)	Risk Assessment 

  

	8)	Partner Maintenance Request Number 

  

	9)	Point of Contact 

  

	 	•	 	 Name, telephone numbers 

  

	10)	Maintenance Install Team 

  

	11)	Update Schedule 

  

	 	•	 	 Cancellation of Maintenance – as soon as possible 

 

	 	•	 	 Start of Maintenance Window 

  

	 	•	 	 Notify when Down Time begins 

  

	 	•	 	 Notify when Information Service is restored (Down Time ends) 

 

	 	•	 	 Notify of Problem 

  

	 	•	 	 Maintenance runs outside window 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commisson.

  

 40 

 Appendix C – Incident Notification 

Incident Notification or Trouble Ticket (send to: *** 
  

	1)	Title of Incident 

  

	2)	Brief Description of Incident 

  

	 	•	 	 Should include scope (AT&T service impacted) 

  

	3)	Start Date and Time 

  

	4)	Information Service Resolution Date and Time 

  

	5)	Duration of Outage 

  

	 	•	 	 Provided at time of restoration 

  

	6)	AT&T Information Service Impact 

  

	 	•	 	 Impact to AT&T End Customer 

  

	7)	Partner Ticket Number 

  

	8)	Partner Severity Level 

  

	 	•	 	 Based on quantified Information Service impact 

  

	9)	Technical Action Take to Correct Incident 

  

	 	•	 	 Steps taken to restore Information Service 

  

	10)	Initial Root Cause 

  

	 	•	 	 Suspect root cause (brief) 

  

	 	•	 	 Formal RCA for SIR 1 or chronic issues of lower severity 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 41 

 Appendix D – SLA Monitoring Requirements 

*** 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 42 

 Appendix E – ATT.Net SLA Calculation Model 

*** 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 47 

 EXHIBIT J 

WORK ORDER 

Work Order No.              

to Second Amended and Restated Wireless Services Agreement #00014249 

Motricity, Inc. (“Motricity”) will perform the Work identified below for AT&T Mobility LLC (“AT&T”), under
the terms and conditions of that certain Second Amended and Restated Wireless Services Agreement #00014249, dated July 22, 2005 between Motricity and AT&T (as amended, the “Agreement”). In consideration of Work below, AT&T
will pay to Motricity the amount(s) set forth below, upon Acceptance, pursuant to Section 5 of the Agreement. 
  

			
	 Work Request Name/Numbers
	  	 Estimated Completion Date

	 Work Request No.             

and/or See attached Work Request Form(s) or Device On-boarding Plan.
	  	Motricity will use commercially reasonable efforts to complete the Work by ___________. Any changes to this date will be mutually agreed upon in writing.
		
	 Amount
	  	 Due Date

	 $            
	  	Forty-five (45) days from receipt of valid invoice.

This Work Order is made under and incorporates the terms and conditions of the Agreement. The terms and conditions set forth in this Work Order are in
addition to and not in substitution of any terms or conditions set forth in the Agreement. Except as specifically modified by this Work Order, the terms and conditions of the Agreement remain in full force and effect. 

 

			
	Motricity, Inc.	  	AT&T Mobility LLC
		
	  
 Authorized
Signature
	  	  
 Authorized
Signature

		
	  
 Printed Name and
Title
	  	  
 Printed Name and
Title

		
	  
 Date
	  	  

Date

  

 48WAP 2.0 Hosting Agreement, dated as of June 24, 2004

 Exhibit 10.4 

Contract No. 750-67761-2004 

 

 

 WAP 2.0 HOSTING AGREEMENT 

 
  

PREMIUM WIRELESS SERVICES USA, INC. 

D/B/A INFOSPACE MOBILE 

AND 

CELLCO PARTNERSHIP 

d/b/a 

VERIZON WIRELESS 

June 24, 2004 

 WAP 2.0 HOSTING AGREEMENT 

This WAP 2.0 Hosting Agreement (“Agreement”), dated as of June 24, 2004 (the “Effective Date”), is made by
and between Premium Wireless Services USA, Inc., a California corporation and a wholly owned subsidiary of InfoSpace, Inc. (“InfoSpace”), with offices at 10940 Wilshire Blvd.,
9th Floor, Los Angeles, CA 90024, and Cellco Partnership
d/b/a Verizon Wireless (“Verizon Wireless”), a Delaware general partnership, having an office and principal place of business at 180 Washington Valley Road, Bedminster, New Jersey 07921. InfoSpace and Verizon Wireless are sometimes
individually referred to herein as a “Party” and may be collectively referred to as the “Parties.” 

RECITALS 
 A. InfoSpace
is in the business of, among other things, providing wireless infrastructure products and services to its customers. 
 B. Verizon Wireless is
in the business of, among other things, providing wireless telecommunications services to its customers. 
 C. Verizon Wireless desires that
InfoSpace provide access to the products and services more particularly described on Exhibit B (collectively, the “Portal Services”), and InfoSpace is willing to provide access to the Portal Services to Verizon Wireless, pursuant to and in
accordance with the terms and conditions set forth in this Agreement. 
 AGREEMENT 

Now, therefore, in consideration of the foregoing, and for other good and valuable consideration, the receipt and sufficiency of which are hereby
acknowledged, the Parties agree as follows: 
  

	1	Definitions and Exhibits 

 All capitalized
terms shall have the meanings ascribed to them in Exhibit A or as otherwise defined in this Agreement. All exhibits attached to this Agreement are hereby incorporated into, and are an integral part of this Agreement. 

 

	2	Rights and Obligations of the Parties 

2.1 InfoSpace Services. Subject to the terms and conditions of this Agreement and during the Term, InfoSpace will make available to Verizon
Wireless the Portal Services described in Exhibit B. 
 2.2 Verizon Wireless Materials. Subject to the terms and conditions of
this Agreement and during the Term, Verizon Wireless hereby grants to InfoSpace the right to include and implement the Verizon Wireless Materials on the Portal Services. 

2.3 Access to Adult Content. If Verizon Wireless elects to make available adult content under the terms of this Agreement, the Parties
shall mutually agree on the terms and conditions governing such availability. 
  

 PAGE 1 

 2.4 Limitations. 
  

	 	a.	Other than as explicitly set forth herein, Verizon Wireless and its Affiliates shall have no right to reproduce or sub-license, re-sell or otherwise distribute all or
any portion of the Portal Services to any Person except that Verizon Wireless may distribute the Portal Services through its direct distribution channel including its communication stores, websites and its indirect distribution channel, including
its authorized agents, retailers and subagents, provided that such distribution and/or sub-distribution is solely within the United States. 

  

	 	b.	Unless otherwise agreed to by the Parties, Verizon Wireless shall not authorize or assist any Third Party to: (i) remove, obscure, or alter any legal notices,
including notices of Intellectual Property Rights present on or in the Portal Services or any other materials provided by InfoSpace, or (ii) insert any interstitial advertisements, pop-up windows, or other items or techniques that would alter
the appearance or presentation of the Portal Services. 

  

	 	c.	InfoSpace shall not itself, and neither shall it authorize nor assist any Third Party in: (i) removing, obscuring, or altering any legal notices, including notices
of Intellectual Property Rights present on or in the Verizon Wireless Materials or any other materials provided by Verizon Wireless, or (ii) insert any interstitial advertisements, pop-up windows, or other items or techniques that would alter
the appearance or presentation of the Verizon Wireless Materials or the Verizon Wireless Services. 

  

	 	d.	Other than in connection with its performance under this Agreement, InfoSpace and its Affiliates shall have no right under this Agreement to reproduce or sub-license,
re-sell or otherwise distribute all or any portion of the Verizon Wireless Materials to any Person. 

  

	 	e.	Each Party shall comply with all then-current applicable laws, rules, and regulations in connection with the exercise of its respective rights and obligations under
this Agreement (including, without limitation, any law, rule or regulation related to individual privacy). 

  

	 	f.	Neither Party will reverse engineer, disassemble, decompile or otherwise attempt to discover the source code or trade secrets for any of the technology belonging to the
other Party. 

 2.5 Technical Cooperation. Each of the Parties agree to provide reasonable technical cooperation to
the other Party in order to implement the Portal Services. In addition, Verizon Wireless shall allow InfoSpace to implement, and/or shall cooperate with InfoSpace upon its request to assist with its implementation of any bug fixes or updates to the
Portal Services. 
 2.6 Project Management. Each Party will appoint a single primary point of contact for project management and
coordination. This individual will be responsible for coordinating internal teams and activities associated with the deployment of the Portal Services; prioritizing issues and change requests; providing internal communication of project schedule and
status; and coordinating meetings and other joint activities between the Parties. 
  

 PAGE 2 

 2.7 Training. As stated in Exhibit G hereto, on a mutually acceptable timeline to be determined by
the Parties, InfoSpace will, as requested by Verizon Wireless, provide training and any associated documentation for Verizon Wireless employees who will train the Verizon Wireless customer service (WDSC) and technical support (WDTS) teams; Verizon
Wireless operations employees (ATAC and Maintenance Engineering); Verizon Wireless Marketing and Business Development employees; and Verizon Wireless Technology Development employees. InfoSpace will provide up to one (1) week of such training
that will be covered by the Setup Fee defined in Exhibit D. This training shall be conducted at a location to be mutually agreed upon by the Parties. Additional training sessions and documentation for Verizon Wireless Operations (ATAC and
Maintenance Engineering), Marketing, Business Development, and Technology Development employees will be billed at InfoSpace’s then-current standard billing rates. 

2.8 Attribution. Overall, InfoSpace is providing white label (no InfoSpace branding) Portal Services for Verizon Wireless. Verizon Wireless
is the service provider as seen by the User. Verizon Wireless will take all calls from Users on any issues related to the Portal Service. InfoSpace will not display any attribution on the Portal Services systems. 

2.9 Nonexclusivity. Each Party acknowledges and agrees that the rights granted to the other Party in this Agreement are non-exclusive, and
that, without limiting the generality of the foregoing, nothing in this Agreement shall be deemed or construed to prohibit either Party from participating in similar business arrangements as those described herein. 

2.10 Verizon Wireless Portal, “Look and Feel.”. Notwithstanding anything to the contrary in this Agreement, Verizon Wireless
acknowledges and agrees that InfoSpace has created, acquired, or otherwise has rights in, and may, in connection with the performance of the services contemplated hereunder, employ, provide, modify, create, acquire or otherwise obtain rights in,
various concepts, ideas, methods, methodologies, procedures, processes, know-how, techniques, models, templates, and generalized features of the structure, sequence, and organization of software, user interfaces, and screen designs, general purpose
software tools, utilities, routines, logic, coherence, and methods of operation of systems. To the extent that InfoSpace uses its intellectual or other property in connection with the performance of the services set forth herein, InfoSpace shall
retain all right, title and interest in and to such property. Verizon Wireless shall acquire no right, title or interest in or to such property. InfoSpace shall have the right, and shall otherwise be free, to design, develop, and deploy for itself
or third parties deliverables, substantially similar to the deliverables provided to Verizon Wireless in connection with this Agreement, subject only to the following sentence. *** The Verizon Wireless portal ‘look and feel’ shall include
the presentation (but not the 
  
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 3 

 
underlying functionality) of each of the Verizon Wireless Persistent Toolbar present on all InfoSpace hosted WAP pages; Verizon Wireless Dynamic Content window present on select Verizon Wireless
hosted WAP pages (Homepage, News, Sports, Weather, Entertainment, Business); Verizon Wireless Vtext.com Text Alerts ‘View My Text Alerts’, ‘Modify My Text Alerts’ and ‘Set My Text Alerts’ WAP pages; and Verizon Wireless
Premium Services Subscription WAP pages. The prohibition set forth in the previous sentence shall be applicable to design specifications proposed or created by InfoSpace, and shall not be deemed to prohibit InfoSpace from building to design
specifications created by independent third parties. 
 2.11 Work Orders. Unless otherwise agreed, the Parties shall use the form
attached hereto as Exhibit E (the “Work Order”) to document all modifications to the Portal Services. The Work Order shall set forth the work to be performed, the associated fees for such work, and any other applicable terms and
conditions. InfoSpace will perform the tasks set forth on each Work Order and will use commercially reasonable efforts to complete such tasks according to the estimated timeline (if any) set forth on each such Work Order. To the extent reasonably
possible, Verizon Wireless will cooperate with InfoSpace and provide such assistance as InfoSpace may reasonably request to fulfill its obligations under each such Work Order. InfoSpace’s obligation to complete the tasks specified in each such
Work Order by the corresponding dates (if any) shall be subject to InfoSpace’s receipt from Verizon Wireless of all necessary Verizon Wireless Materials and/or technical specifications, if any, by the date set forth in each such Work Order for
delivery of such materials, or if no date is set forth, by a date to be mutually agreed by the Parties. Unless otherwise specifically noted, all Work Orders shall be made under and incorporate the terms and conditions of this Agreement. 

 

	3	Payments 

 3.1 Payment
Terms. Verizon Wireless shall remit payment to InfoSpace for undisputed amounts within forty-five (45) days from Verizon Wireless’ receipt of InfoSpace’s monthly invoice for services rendered. If Verizon Wireless disputes any
charge shown on an InfoSpace invoice, Verizon Wireless shall pay the undisputed amounts per the terms of this Agreement and notify InfoSpace within *** of Verizon Wireless’ receipt of the invoice containing the disputed amounts. The Parties
will work together to resolve any disputed amounts. InfoSpace shall send all invoices via courier service, with confirmation of receipt requested, to: 

Verizon Wireless 
 2785 Mitchell Drive, ***

 Walnut Creek, CA 94598 
 Attention:
*** 
 3.2 Fees and Payments. Verizon Wireless shall pay to InfoSpace the fees set forth on Exhibit D in accordance with the terms
and conditions of this Agreement and as set forth herein and on Exhibit D. 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 4 

 3.3 No Additional Fees for Link Changes. For a period of *** following the Commercial Service
Date, the Parties agree that Verizon Wireless shall pay InfoSpace no additional fee for adding or changing links using Deck Manager. 
 3.4
Verizon Wireless Audit of InfoSpace’s Obligations 
  

	 	a.	During the Term of this Agreement and *** thereafter, InfoSpace agrees to keep all usual and proper books and records relating to its performance under this Agreement.
All such records shall be maintained in accordance with Generally Accepted Accounting Practices (GAAP). To verify InfoSpace’s compliance with this Agreement, Verizon Wireless may, during the Term of this Agreement and for ***, review copies of
InfoSpace’s books and records strictly relating to reports and/or payments due under this Agreement. Any audit or inspection under this Section will be conducted *** by Verizon Wireless, and in manner that does not unreasonably interfere with
InfoSpace operations. InfoSpace agrees to provide Verizon Wireless’ designated audit and/or inspection team with copies of all relevant books and records strictly relating to reports and/or payments due under this Agreement.

  

	 	b.	If any audit or inspection conducted under this Section reveals that InfoSpace’s reporting has caused Verizon Wireless to materially over-pay fees due hereunder,
InfoSpace will pay the costs incurred by Verizon Wireless as the result of its conducting such audit or inspection. Otherwise, Verizon Wireless will pay the costs incurred by Verizon Wireless as the result of its conducting such audit or inspection.

  

	 	c.	For purposes of this Section, “materially” shall mean that the actual amount that Verizon Wireless should have paid, as disclosed by the audit, is more than
*** less than that which Verizon Wireless has actually paid for the audited payment period. 

  

	 	d.	Verizon Wireless shall be entitled to conduct an audit or inspection under the terms of this Section ***. 

 

	 	e.	The results of any inspection or audit hereunder will be subject to the confidentiality obligations referenced in Section 14 of this Agreement.

 3.5 Remuneration; Collection 

InfoSpace may accept any check or payment without prejudice to its rights to recover the balance due or to pursue any other right or remedy. No
endorsement or statement on any check or payment or letter accompanying any check or payment or elsewhere will be construed as an accord or satisfaction. Unless explicitly stated on Exhibit D, all amounts payable under this Agreement are denominated
in United States dollars. In the event Verizon Wireless fails to make timely payment of any undisputed amount due and owing, InfoSpace shall have the right, in addition to all other remedies, to escalate the issue as per the terms outlined in
Section 10 of this Agreement. 
  
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 5 

 3.6 Taxes. 
  

	 	a.	Subject to Section 3.6(c), if the Party receiving an amount paid pursuant to this Agreement (“Payee”) from the other Party (“Payor”) is
required by law to collect any federal, state or local sales, excise or other similar tax from Payor (or if Payee is permitted by law to collect such tax from Payor and such tax is of a type which is customarily collected from buyers by sellers),
then: (i) Payee shall bill such tax to Payor in the manner and for the amount required by law, (ii) Payor shall pay such billed amount of tax to Payee, and (iii) Payee shall remit such billed amount of tax to the appropriate tax
authorities as required by law. 

  

	 	b.	Except as provided in Section 3.6(a), each Party shall bear its own liability under applicable law for all import and export duties and other governmental fees and
taxes of whatever nature (including, without limiting the generality of the foregoing, any penalty, addition to tax or interest imposed with respect to such duties, fees or taxes) with respect to the transactions contemplated by this Agreement.

  

	 	c.	Payee shall not bill to or otherwise attempt to collect from Payor any tax with respect to which Payor has provided Payee with an exemption certificate, direct pay
number, or other reasonable basis for relieving Payee of its responsibility to collect such tax from Payor. 

  

	 	d.	If a Party is required by law to collect any federal, state or local sales, excise or other similar tax from its customer with respect to an amount to be paid by such
customer for goods or services sold by such Party which incorporate one or more service or other elements furnished by the other Party, then, as between the Parties, the Party with the customer relationship shall be responsible for: (i) billing
such tax to such customer in the manner and for the amount required by law, (ii) collecting such billed amount of tax from such customer, and (iii) remitting such billed amount of tax to the appropriate tax authorities as required by law.

  

	 	e.	Each Party will cooperate, to the extent reasonably requested by the other Party, in connection with any refund claims for taxes and in connection with any audit,
litigation or other proceeding with respect to taxes which involves the transactions contemplated by this Agreement. 

  

	 	f.	 Except with respect to taxes described in Section 3.6(a), if any payments made by or on behalf of Payor under this Agreement are subject to any
taxes, levies, customs, duties, deductions, charges or withholdings, or are subject to any other governmental liability or charge, including, without limiting the generality of the foregoing, any penalty, addition to tax or interest (each, a
“Governmental Charge”), and Payor actually pays such Governmental Charge as required by law, then, to the extent that the payment of such Governmental Charge by Payor reduces a direct liability of Payee, Payor shall receive full credit
from Payee for such payment as if it was an amount paid directly by Payor to Payee with respect to the amounts payable by Payor to Payee under this Agreement. Upon Payee’s

  

 PAGE 6 

	 	
request, Payor shall promptly take, at Payee’s expense, all actions reasonably requested by Payee to mitigate the aggregate amount of Governmental Charges (including, without limiting the
generality of the foregoing, the accurate completion of forms, certificates and documents and the provision of accurate, non-confidential information to the relevant taxing authority); provided, however, that Payor shall not be required to take any
such action which would subject Payor to any un-reimbursed expense. If Payor receives a receipt with respect to a Governmental Charge, then Payor shall furnish to Payee the original or a certified copy of such receipt. 

 

	4	User Data. 

 4.1 Ownership of User
Data. Subject to the terms of applicable user agreements and this Section 4, Verizon Wireless shall own all rights in the User Data which it collects, or which is collected on its behalf during the Term of this Agreement. 

4.2 Security of User Data. InfoSpace will use its best efforts to sufficiently protect the User Data from disclosure to or unauthorized access by
any Third Party, or from becoming corrupt. These efforts shall include data encryption, application and network security and/or restricted access controls. InfoSpace shall abide by the policies and security standards described in Exhibit O,
“Computing Security Policy.” With reference to Exhibit O, as it applies to Verizon Wireless Portal Services: Data Type is defined as Customer Information; Data Access is defined as Limited Group; and Data Type Owner is defined as User
Manager and Deck Manager. All of the systems that make up the Verizon Wireless Portal Services are deemed business critical systems and are within the scope of the InfoSpace Disaster Recovery Plan, as defined in Exhibit O. InfoSpace shall provide
Verizon Wireless with prior written notice of any major changes to Exhibit O, as defined therein.  
 4.3 Ownership of MIN and
MDN. The Parties further agree that Verizon Wireless shall own and retain control over each User’s mobile identification number (“MIN”) and mobile dialing number (“MDN”). Should InfoSpace capture a User’s MIN or
MDN, InfoSpace shall be entitled to use said information only in providing the Portal Services to Users under the terms and conditions of this Agreement. 

4.4 Aggregate Information Generated in the Portal Services. With respect to Aggregate Information generated specifically by use of the Portal
Services by Users, the Parties agree that each may collect the Aggregate Information, and that subject to the terms of any applicable user agreements and of this Section 4, Verizon Wireless shall own the rights thereto. Any use of Aggregate
Information generated by the Portal Services: (a) must be used in accordance with the Verizon Wireless privacy policy, (b) must be used in accordance with applicable law, and (c) may not be provided or made available, in any form or
manner, to any Third Party during the Term without the prior written approval of Verizon Wireless. Notwithstanding the foregoing, InfoSpace may track and use Aggregate Information about use of the Portal Services, including, but not limited to usage
patterns and other aggregate data for statistical analysis, internal product analysis and development, de-bugging, system maintenance purposes, and for the performance of its obligations under this Agreement. InfoSpace may report such Aggregate
Information to Third Parties solely for purposes of promoting InfoSpace and/or InfoSpace products and services in connection with marketing, investor relations and/or advertising-related activities, provided that InfoSpace shall not specify that the
Aggregate Information is attributable to Verizon Wireless. 
  

 PAGE 7 

 4.5 User Data Obtained by InfoSpace. 

Except as set forth in Section 4.4, User Data that is obtained by InfoSpace: 

 

	 	a.	from the provision or operation of the Portal Services, or 

  

	 	b.	during User’s use of the Portal Services, or 

  

	 	c.	during User’s registration for Portal Services, 

may only be used by InfoSpace: 
  

	 	i.	Consistent with the Verizon Wireless privacy policy attached as Exhibit K, 

 

	 	ii.	consistent with all applicable law, 

  

	 	iii.	solely in connection with the provision of the Portal Services, and 

  

	 	iv.	at the User’s option and consent, to promote products/services other than the Portal Services, provided Verizon Wireless also gives its prior written consent.

  

	5	Service Level Agreement; Adverse Impact; Operational Obligations; Viruses. 

5.1 Service Level Agreement. Attached as Exhibit H is a Service Level Agreement (“SLA”) setting forth the respective
responsibilities of the Parties regarding support of the Portal Services. 
 5.2 Adverse Impact. Should an Adverse Impact occur: 

  

	 	a.	Verizon Wireless: 

  

	 	i.	will use its best efforts to notify InfoSpace immediately of such Adverse Impact, 

 

	 	ii.	may ***, to the extent Verizon Wireless determines such is necessary to halt the Adverse Impact, 

 

	 	iii.	may ***, to the extent Verizon Wireless determines such is necessary to halt the Adverse Impact. 

 

	 	b.	InfoSpace: 

  

	 	i.	will use its best efforts to notify Verizon Wireless upon becoming aware of any indication that the Portal Services may have caused the Adverse Impact,

  
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 8 

	 	ii.	will, upon becoming aware of any indication that the Portal Services may have caused the Adverse Impact, ***: 

*** 
 (C)
promptly remedy any negative condition caused by the Adverse Impact, and/or 
 *** 

 

	 	c.	As promptly as practical after the occurrence of the Adverse Impact, the Parties agree to meet in order to discuss the Adverse Impact, its causes, ***, and possible
long-term remedial steps. 

  

	 	d.	The Parties agree to use best efforts to ***, consistent with the goal of avoiding any further Adverse Impact. 

 

	 	e.	If, after implementing the remedies set forth in this Section, the Adverse Impact persists, then Verizon Wireless may terminate this Agreement ***.

  

	 	f.	To the extent the process for addressing an Adverse Impact set forth in this Section conflicts with the Service Level Agreement,***. 

5.3 Other Operational Obligations. 
  

	 	a.	Network. During the Term, Verizon Wireless shall use commercially reasonable efforts to maintain the Verizon Wireless Network, and shall provide Users with access to
the Portal Services via such Verizon Wireless Network. 

  

	 	b.	Portal Services Security. 

 To
the extent a component of the Portal Services is owned by or under the control of either of the respective Parties, and in addition to the Parties’ specific obligations with regard to viruses (as stated in Section 5.4 of this Agreement),
each Party agrees to use reasonable and good faith efforts to maintain the security and integrity of said components. 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 9 

	 	i.	In the event that the security and/or integrity of the Portal Services, or any component thereof, is somehow compromised, the Parties agree to notify the other Party of
such security compromise as ***, and to use their best efforts to cure said compromise ***. 

  

	 	ii.	As a part of using their best efforts to cure any compromise, the Parties shall: 

(A) ***, 
 (B)
promptly remove from the Portal Services element(s) affected by the compromise, 
 (C) promptly remedy any adverse condition
caused by the compromise, 
 (D) ***, 

(E) *** 
 (F)
*** reinstate any such Portal Services elements that have been removed ***, consistent with the goal of avoiding any further compromise. 
  

	 	iii.	With respect to compromises for which InfoSpace is solely responsible, if the compromise persists after implementing the remedies set forth in this Section, Verizon
Wireless may terminate this Agreement ***. 

  

	 	iv.	To the extent the process for addressing a compromise set forth in this Section conflicts with the Service Level Agreement, ***. 

 

	 	c.	Unsolicited Data or Messaging (“Spam”). The Parties agree to implement procedures and to use commercially reasonable efforts to prevent Third Parties from
sending or transmitting unsolicited WAP push or SMS messages to Users. Each Party agrees to notify the other Party if it knows or has reason to know that Spam is being sent to Users by Third Parties, and agrees to use commercially reasonable efforts
to prevent and/or block 

  
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 10 

	 	
any such Spam originated in connection with the Portal Services from being sent to Users by way of their Wireless Devices. The Parties agree to promptly notify the other Party if it knows or has
reason to know that Users are being sent an unusual or abnormal flow, number or type of Spam. In the event that a User is being sent Spam originated in connection with the Portal Services, or one Party notifies the other Party that Users are being
sent Spam originated in connection with the Portal Services, the Parties will use commercially reasonable efforts to prevent continuing transmission of such Spam. 

5.4 Viruses. 
 The Parties agree that
each will use its reasonable and good faith efforts to ensure that it does not introduce a Virus, Self-Help Code, or Unauthorized Code into the other Party’s system or network. InfoSpace agrees that it will use reasonable and good faith efforts
to ensure that all Electronically Transmitted Information does not contain and/or will not contain any Virus, Self-Help Code, or Unauthorized Code. InfoSpace further agrees that in the normal course of business, it will continually monitor the
Electronically Transmitted Information for the presence of any Virus, Self-Help Code, or Unauthorized Code. In the event either Party detects the presence of any such Virus, Self-Help Code, or Unauthorized Code, it will use its best efforts to:
(a) notify the other Party of such, (b) promptly as reasonably appropriate remove the Virus, Self-Help Code, or Unauthorized Code, to the extent such removal is within the control of the respective Party, and (c) promptly remedy any
condition caused by the Virus, Self-Help Code, or Unauthorized Code, to the extent a remedy is within the control of the respective Party. In the event a Virus, Self-Help Code, or Unauthorized Code is discovered by one Party (the “Discovering
Party”), the other Party (the “Non-discovering Party”) will use all available commercially reasonable efforts, to assist the Discovering Party in its efforts to remove the Virus, Self-Help Code, or Unauthorized Code as is required
hereinabove. 
  

	6	Foreign Based Services. InfoSpace represents, warrants and covenants that no service performed by InfoSpace pursuant to this Agreement shall be provided,
directed, controlled, supervised, or managed, and no data or Verizon Wireless customer communication (voice or data) relating to any such service shall be stored or transmitted at, in, or through a site located outside of the United States without
the advance written consent of Verizon Wireless. 

  

 PAGE 11 

	7	CALEA Compliance. To the extent the Communications Assistance for Law Enforcement Act (Pub L. 103-414, Title 1, October 25, 1994, 108 Stat 4279, as
amended) (“CALEA”) is directly applicable to the services provided by InfoSpace under the terms of this Agreement, InfoSpace represents and warrants to Verizon Wireless that at the time of delivery and throughout the Term, all products,
Portal Services and software delivered hereunder shall be “CALEA Compliant,” meaning that they will comply with the provisions of CALEA, as well as any regulations or industry standards implementing the provisions of the law. To the extent
CALEA is directly applicable to the services provided by InfoSpace under the terms of this Agreement, InfoSpace shall defend, indemnify and hold harmless Verizon Wireless and Verizon Wireless’ customers for any loss, cost, or damages
(including, but not limited to, attorney’s fees) sustained because of InfoSpace’s CALEA noncompliance. 

  

	8	Term and Termination 

 8.1
Term. The term of this Agreement shall commence on the Effective Date and, unless earlier terminated pursuant to the terms of this Agreement, shall end on the third anniversary of the Commercial Service Date (the “Term”);
provided that the Term shall be automatically renewed for successive 6 month periods unless either party provides written notice of termination to the other Party at least ninety (90) days prior to the end of the then-current Term. 

8.2 Termination. Except as expressly provided elsewhere in this Agreement, either Party may terminate this Agreement under the following
conditions: 
  

	 	a.	For Cause. Either Party may terminate this Agreement if the other Party is in material breach hereof, and with the exception of breaches involving violations of the
law, provided the allegedly breaching Party has not cured such alleged material breach to the reasonable satisfaction of the non-breaching Party within thirty (30) days after having been notified, in writing, of the alleged material breach.

  

	 	b.	For Bankruptcy/Insolvency. Either Party may terminate this Agreement immediately following written notice to the other Party, if the noticing Party: (a) ceases to
do business in the normal course, (b) becomes or is declared insolvent or bankrupt, (c) is the subject of any proceeding related to its liquidation or insolvency (whether voluntary or involuntary) which is not dismissed within ninety
(90) calendar days, or (d) makes an assignment for the benefit of creditors. 

  

	 	c.	***. 

  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 12 

 8.3 Effect of Termination. Upon the expiration or termination of this Agreement, and in each case
subject to the respective Party’s continuing obligations with respect to the Transition Period: 
  

	 	a.	Both Parties shall cease, ***, all use of the Intellectual Property of the other Party, other than Intellectual Property which may be covered by a separate license
agreement, 

  

	 	b.	***, both Parties shall return to the other Party all materials containing any Intellectual Property of the other Party, other than those materials containing
Intellectual Property which may be covered by a separate license agreement, 

  

	 	c.	***, both Parties shall return to the other Party all materials identifying or otherwise relating to the other Party’s business, 

 

	 	d.	***, both Parties shall immediately cease representing themselves as a marketing, branding or service affiliate of the other, 

 

	 	e.	***. 

  

	 	f.	***, 

  

	 	g.	*** 

  

	 	h.	Termination of this Agreement shall not affect any separate contractual obligations or commitments, existing or made prior to the termination date of this Agreement,
that either Party may have to Users. 

 8.4 Survival. Upon termination of this Agreement for any reason or upon expiration
of the Term, the rights and obligations of the Parties under Sections 3.1, 3.2, 3.4, 3.5, 4, 7, 8, 9, 10, 11, 13, and 14 shall survive any termination or expiration of the Term. 

 

	9	Transition Period 

 9.1 Transition
Period Generally. 
  

	 	a.	Notwithstanding any other provision in this Agreement and subject to Section 9.1(d) below, upon the expiration or termination of this Agreement ***, InfoSpace will
continue to provide the Portal Services to Verizon Wireless for a specific period of time to be agreed by the Parties ***. In addition, during the Transition Period, InfoSpace agrees to provide reasonable Transition Services that Verizon Wireless
may reasonably request to transition the Portal Services provided by InfoSpace to Verizon Wireless or a Third Party (the “Transition Services”), subject to Section 9.1(d) below. 

 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 13 

	 	b.	***. 

  

	 	c.	InfoSpace agrees that during the Transition Period, it will permit Verizon Wireless to include on Wireless Devices a link to the Portal Services, in order to permit
Users to have direct access to the Portal Services. 

  

	 	d.	***. In the event that Verizon Wireless requests Transition Services, InfoSpace and Verizon Wireless shall agree to a statement of work and an associated fee structure
before any transition work is started. 

  

	 	e.	During the Transition Period, the obligations of the Parties as set forth hereunder shall survive. 

 

	 	f.	Any communications made to Users following the termination or expiration of the Agreement relating to wireless data shall be mutually agreed to by the Parties. ***.

  

	10	Committees, Designated Managers, Plan Updates and Escalation of Disputes. 

10.1 Executive Committee. The Parties agree that in order to facilitate the meeting of all terms, conditions and obligations of this Agreement, and
to further the anticipated cooperation hereunder, they shall form an executive steering committee (the “Executive Committee”) which will review and resolve issues and disputes which have been escalated from the Steering Committee.

  

	 	a.	Structure of the Executive Committee. The Parties will designate executives from their respective companies, to serve as members of the Executive Committee. The
Executive Committee will be comprised of one (1) member appointed by Verizon Wireless and one (1) member appointed by InfoSpace. Each of the committee members shall act in the interests of the Party who appointed that member.

  

	 	b.	Executive Committee Meetings. The Executive Committee shall meet as often as necessary, at mutually acceptable times and locations. The Parties agree that Steering
Committee members and Designated Managers may attend meetings of the Executive Committee as deemed appropriate by the Executive Committee. 

  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 14 

 10.2 Steering Committee. The Parties agree that in order to facilitate the meeting of all terms,
conditions and obligations of this Agreement, and to further the anticipated cooperation hereunder, they shall form a steering committee (the “Steering Committee”) which will: (a) review the performance of the Project, and
(b) identify performance metrics for monitoring performance pursuant to the Project. 
  

	 	a.	Structure of the Steering Committee. The Parties will designate executives from their respective companies to serve as members of the Steering Committee. The Steering
Committee will be comprised of four (4) members, two (2) appointed by Verizon Wireless and two (2) appointed by InfoSpace. Each of the committee members shall act in the interests of the Party who appointed that member.

  

	 	b.	Meetings. The Steering Committee shall meet as often as necessary, either in person or by telephone, at mutually acceptable times and locations. At such meetings, the
Parties shall provide reports on their company’s performance pursuant to the Project. 

 10.3 Designated Managers.
Each Party shall designate managers (the “Designated Managers”) who shall coordinate the Parties’ respective obligations under this Agreement and the implementation of all terms and conditions contained herein. The Designated Managers
shall be employees of Verizon Wireless and InfoSpace tasked to oversee the performance of the Project and to periodically report to the Steering Committee. Each Party may change its Designated Manager(s) from time-to-time, but shall inform the other
Party of such a change. 
 10.4 Escalation of Disputes. In the event any dispute, claim, question or difference between the Parties (a
“Dispute”) arises with respect to the Agreement or the Parties’ performance, enforcement, breach, or termination thereof, the Parties shall use their best efforts to settle the Dispute as follows: 

 

	 	a.	First the Designated Managers shall consult and negotiate with each other for at least ten (10) business days [five (5) business days in the case of late or
disputed payments], in good faith and understanding of their mutual interests, in an attempt to reach a just and equitable solution satisfactory to all Parties. 

 

	 	b.	If the Designated Managers are unable to resolve the Dispute in the aforesaid time, either Party may escalate the Dispute to the Steering Committee for a further ten
(10) business day [five (5) business days in the case of late or disputed payments] consultation and negotiation. 

  

	 	c.	If the Steering Committee is unable to resolve the Dispute in the aforesaid time, either Party may escalate the Dispute to the Executive Committee for a further ten
(10) business days [five (5) business days in the case of late or disputed payments], of consultation and negotiation. 

  

	 	d.	Only after exhausting their efforts under this Section may either Party invoke the arbitration procedures under Section 15.6 of this Agreement.

  

	 	e.	 However, either Party may at any time, give notice and seek injunctive relief, including, but not limited to a temporary restraining order against the
other Party for alleged breaches of this Agreement in any court of competent jurisdiction. Each Party acknowledges that monetary damages 

 

 PAGE 15 

	 	
may not be a sufficient remedy for unauthorized disclosure of Confidential Information or misuse of Intellectual Property, and that the disclosing Party shall be entitled, without waiving any
other rights or remedies, to seek such injunctive or equitable relief as may be deemed proper by a court of competent jurisdiction. 

  

	11	Warranties, Indemnification and Limitation of Liability 

11.1 Mutual Warranties. Each Party represents and warrants to the other Party that: 

 

	 	a.	It has the full corporate right, power and authority to enter into this Agreement and to perform the acts required of it hereunder; 

 

	 	b.	The execution of this Agreement by such Party and performance of its obligations hereunder, do not and will not violate any agreement to which it is a party or by which
it is bound; 

  

	 	c.	Such Party has obtained, and shall maintain in full force during the Term hereof, such federal, state and local authorizations as are necessary to operate and to
otherwise perform its obligations under this Agreement, and shall be in substantial compliance with all applicable laws and regulations governing such performance. 

 

	 	d.	When executed and delivered, this Agreement will constitute the legal, valid and binding obligation of such Party, enforceable against it in accordance with its terms;

  

	 	e.	It has the authority to grant the other Party all of the rights granted in this Agreement; 

 

	 	f.	It shall conduct its efforts under this Agreement in accordance with all applicable federal, state and local laws and regulations and shall promptly comply with any
notices received from any governmental entity having authority or jurisdiction over such Party regarding compliance with any federal, state or local laws. 

11.2 InfoSpace Warranties. InfoSpace represents and warrants to Verizon Wireless that: 

 

	 	a.	 The execution of this Agreement by InfoSpace and the performance of its obligations hereunder do not and will not infringe any Intellectual Property
Rights of any Third Party. However, in the event that the Portal Services become the subject of a claim that the Portal Services infringe any copyright, trade secret or United States patent, InfoSpace may, at its option: (i) procure for Verizon
Wireless the right to use the Portal Services free of any liability; or (ii) replace or modify, in whole or in part, the Portal Services to make them non-infringing. Notwithstanding the warranty stated in the first sentence of this Section, in
the event that the Portal Services become the subject of a claim that the Portal Services infringe any copyright, trade secret or United States patent and in the event InfoSpace can not or will not perform the action described in

  

 PAGE 16 

	 	
Section 11.2 a. (i) and (ii), Verizon Wireless may, at its option, terminate this Agreement. InfoSpace’s resolution of any actual or alleged infringement pursuant to (i) or
(ii) above will not constitute a breach of the warranty set forth in this Section. 

  

	 	b.	InfoSpace itself will not knowingly include in the Portal Services, any obscene, threatening, abusive, harassing, defamatory, libelous, infringing or unlawful content
or code, whether or not readily discernable or capable of detection by the average user. In the event that Verizon Wireless determines that certain content is objectionable in contravention of the preceding sentence, InfoSpace will not be deemed to
be in breach of this Agreement provided that InfoSpace removes the offending content as soon as is reasonably possible following notification by Verizon Wireless of such offending content. Notwithstanding the foregoing, Verizon Wireless acknowledges
that InfoSpace does not have an obligation to review content provided to Users by Third Parties via the Portal Services and that InfoSpace will not incur any liability whatsoever with respect to the nature of such content. 

 

	 	c.	It will perform its obligations under this Agreement in a workman-like manner. 

 

	 	d.	It will not make any representations or warranties as to the quality of the Verizon Wireless Services or the Verizon Wireless Network, except as may be specifically
authorized, in writing, by Verizon Wireless as to carry out the intent of this Agreement. 

  

	 	e.	InfoSpace represents and warrants that the Portal Services shall operate in substantial conformity with the specifications contained in Exhibit J.

 11.3 Verizon Wireless Warranty. Verizon Wireless represents and warrants to InfoSpace that the Verizon Wireless
Materials that Verizon Wireless provides to InfoSpace for use in connection with the Portal Services under the terms of this Agreement do not and will not infringe any Intellectual Property Rights of any Third Party. 

11.4 Disclaimer. EXCEPT FOR THE FOREGOING, NEITHER PARTY MAKES, AND EACH PARTY HEREBY SPECIFICALLY DISCLAIMS, ANY WARRANTIES, EXPRESS OR IMPLIED,
REGARDING ITS PERFORMANCE HEREUNDER, INCLUDING, WITHOUT LIMITATION, IMPLIED WARRANTIES OF FITNESS OR MERCHANTABILITY, AND WARRANTIES ARISING BY COURSE OF PERFORMANCE OR TRADE USAGE. WITHOUT LIMITING THE GENERALITY OF THE FOREGOING, VERIZON WIRELESS
ACKNOWLEDGES THAT THE PORTAL SERVICES ARE PROVIDED “AS IS” WITHOUT ANY WARRANTIES OF ANY KIND. 
 EXCEPT AS OTHERWISE EXPRESSLY
PROVIDED FOR IN THIS AGREEMENT OR IN ANY EXHIBIT HERETO, VERIZON WIRELESS MAKES NO REPRESENTATION OR WARRANTY CONCERNING THE AVAILABILITY OF THE VERIZON WIRELESS SERVICES OR THE VERIZON WIRELESS NETWORK,

  

 PAGE 17 

 
ITS FACILITIES OR CAPACITY; AND NEITHER DOES VERIZON WIRELESS WARRANT OR REPRESENT THAT ACCESS TO OR USE OF THE VERIZON WIRELESS SERVICES OR THE VERIZON WIRELESS NETWORK SHALL BE UNINTERRUPTED OR
ERROR-FREE. 
 11.5 Indemnification. 
  

	 	a.	InfoSpace shall, at its own expense and at the request of Verizon Wireless, defend any Third Party claim or action brought against Verizon Wireless, and/or its
Affiliates, directors, officers, employees, licensees, agents and independent contractors, to the extent such claim or action is based upon: 

  

	 	i.	a claim that any material supplied by InfoSpace or its authorized representative with respect to or in the Portal Services, excluding material supplied to InfoSpace by
Verizon Wireless, but including, without limitation, the InfoSpace Marks, links provided by InfoSpace or its authorized representative, and the InfoSpace Content accessed by such links: 

(A) infringes the copyrights, patents, trademarks, service marks, or trade secrets, or violates any privacy or publicity rights of any
Third Party, or that InfoSpace is not the sole and exclusive owner of, or that it does not have the express written right to the Portal Services and all other materials provided by InfoSpace under the terms of this Agreement, 

(B) is factually inaccurate in any material respect, or 

(C) contains information, instructions or formulas that are injurious to a Third Party’s physical well-being, or that defames or
disparages a Third Party, 
  

	 	ii.	a claim that any act or omission by InfoSpace or its authorized representative in connection with its performance under this Agreement violates any applicable law or
regulation, 

  

	 	iii.	a claim that, if true, would constitute a breach of a warranty, representation or covenant of InfoSpace as set forth in this Agreement, and/or 

 

	 	iv.	a claim that InfoSpace has misused any Verizon Wireless User Data. 

  

	 	b.	Verizon Wireless shall, at its own expense and at the request of InfoSpace, defend any Third Party claim or action brought against InfoSpace, its Affiliates, directors,
officers, employees, licensees, agents and independent contractors, to the extent such claim or action is based upon: 

  

	 	i.	a claim that any material supplied by Verizon Wireless or its authorized representative with respect to the Portal Services, excluding material supplied to Verizon
Wireless by InfoSpace, but including, without limitation, the Verizon Wireless Marks, links provided by Verizon Wireless or its authorized representative, the Verizon Wireless Content accessed by such links, and any content provided by Verizon
Wireless or its authorized representatives: 

 (A) infringes the copyrights, patents, trademarks, service marks,
or trade secrets, or violates any privacy or publicity rights of any Third Party, or that Verizon Wireless is not the sole and exclusive owner of, or that it does not have the express written right to the Verizon Wireless Services and all other
materials provided by Verizon Wireless under the terms of this Agreement, 
  

 PAGE 18 

 *** 
  

	 	iv.	to the extent Verizon Wireless receives such indemnification from its Third Party Content providers, a claim (including civil or criminal penalties levied by any
governmental agency): (i) arising from, or related to, any Third Party content, links or materials provided by Verizon Wireless or its vendors in connection with the Portal Services, including without limitation any claims based on the obscene,
pornographic, profane, fraudulent, libelous or defamatory nature of any Third Party content, links or materials supplied by Verizon Wireless or its vendors to InfoSpace in connection with the Portal Services, or (ii) arising from, or related
to, any User information that InfoSpace discloses to Third Parties at Verizon’s request. 

  

	 	c.	For the purposes hereof, the “Indemnifying Party” shall mean the Party having indemnification obligations pursuant to Sections 11.5(a) and/or 11.5(b) above.
The “Indemnified Party” shall mean the Party and/or all applicable Third Parties being indemnified pursuant to and identified in Sections 11.5 (a) or 11.5(b) above. “Indemnified Claims” shall mean those claims for which the
Indemnified Party is to be indemnified pursuant to Sections 11.5(a) or 11.5(b) above. 

  

	 	d.	In such cases where a Third Party claim or action is brought against either Party, the Indemnified Party shall promptly notify the Indemnifying Party, in writing,
specifying the nature of the claim or action, including the total monetary amount sought or other such relief as stated therein. The 

  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 19 

	 	
Indemnified Party shall (i)cooperate with the Indemnifying Party, at the Indemnifying Party’s expense, in all reasonable respects in connection with the defense of any such claim or action
and (ii) at the Indemnified Party’s expense, be entitled to participate in the defense of any such claim. 

  

	 	e.	The Indemnified Party agrees that the Indemnifying Party shall have sole and exclusive control over the defense and settlement of any such third party claim.

  

	 	f.	In the event the Indemnifying Party elects not to undertake to control and conduct all proceedings or negotiations in connection with the defense of any claim or action
under this Section, the Indemnified Party shall have the right to enter a reasonable and good faith settlement with respect to any such claim or action upon providing the Indemnifying Party with 10 days notice of the Indemnified Party’s intent
to enter such reasonable and good faith settlement agreement. With respect to the foregoing: (i) an Indemnified Party shall not settle any claim or action under this Section without first seeking the Indemnifying Party’s permission, which
permission shall not be unreasonably withheld, and (ii) the Indemnifying Party shall issue payment, if applicable, to the Third Party claimant in accordance with the terms and conditions of the subject settlement agreement.

  

	 	g.	In consultation with and subject to the approval of the Indemnifying Party, the Indemnified Party shall have the right, to employ separate counsel to provide input into
the defense, at the Indemnified Party’s own cost. The Indemnifying Party shall reimburse the Indemnified Party, within 60 days of demand, for any payments made or loss suffered by it at any time after the date of tender, based upon the judgment
of any court of competent jurisdiction or pursuant to a reasonable, good faith and bona fide compromise or settlement of claims, demands, or actions, in respect to any damages to which the foregoing relates. 

 

	 	h.	The Indemnifying Party shall have the right to enter a reasonable and good faith settlement or compromise with respect to any claim or action under this Section,
provided that the Indemnifying Party shall not settle any such claim or action under this Section on the Indemnified Party’s behalf without first obtaining the Indemnified Party’s written permission, which permission shall not be
unreasonably withheld. 

  

	 	i.	The Indemnifying Party shall indemnify and hold the Indemnified Party harmless from and against any reasonable costs, damages and fees reasonably incurred by the
Indemnified Party, including but not limited to reasonable fees of attorneys and other professionals, that are attributable to such Indemnified Claims. The Indemnified Party shall not settle any Indemnified Claims without the prior written consent
of the Indemnifying Party, which consent shall not be unreasonably withheld. 

  

 PAGE 20 

 11.6 Limitation of Liability. 

EXCEPT IN CONNECTION WITH THE GROSS NEGLIGENCE OR INTENTIONAL MISCONDUCT *** FOR ANY INDIRECT, INCIDENTAL, CONSEQUENTIAL, PUNITIVE OR SPECIAL DAMAGES
ARISING OUT OF OR RELATED TO THIS AGREEMENT ***, EVEN IF *** HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES. THE FOREGOING SENTENCE SHALL NOT APPLY TO *** BREACH OF THE CONFIDENTIALITY OBLIGATIONS REFERENCED IN SECTION 14 OR EITHER PARTY’S
INDEMNIFICATION OBLIGATIONS REFERENCED IN SECTION 11 *** 
  

	12	Intellectual Property. 

 12.1 Verizon
Wireless. As between the Parties, Verizon Wireless reserves and retains all right, title and interest in and to the Verizon Wireless Marks and Verizon Wireless Materials, along with all Intellectual Property Rights associated therewith.
Additionally, Verizon Wireless reserves and retains all right, title and interest in and to all Intellectual Property created by Verizon Wireless, provided that such Intellectual Property does not constitute an Enhancement (as defined in
Section 11.9(a)) of InfoSpace Intellectual Property. 
 12.2 InfoSpace. As between the Parties, InfoSpace reserves and retains all
right, title and interest in and to the InfoSpace Marks, the Portal Services (excluding the Verizon Wireless Materials and rights retained by Verizon Wireless as described in Section 11.1 above) and the Technology utilized under or in
connection with this Agreement, including but not limited to all Intellectual Property Rights associated therewith. 
 12.3 Verizon Wireless
Marks License. Subject to Section 12.5 and Exhibit C, Verizon Wireless hereby grants to Premium Wireless Services and it’s parent company InfoSpace, Inc the right to use, reproduce, publish, perform and display the Verizon Wireless
Marks in connection with the development, use, reproduction, modification, adaptation, publication, display and performance of the Portal Services. 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 21 

 12.4 InfoSpace Marks License. Subject to Section 12.5 and Exhibit C, InfoSpace hereby grants to
Verizon Wireless the right to use, reproduce, publish, perform and display the InfoSpace Marks: (a) in connection with the development, use, reproduction, modification, adaptation, publication, display and performance of the Portal Services;
and (b) in promotional and marketing materials, content directories and indices, and electronic and printed advertising, publicity, newsletters and mailings about Verizon Wireless and its relationship with InfoSpace and the Portal Services.

 12.5 Use of Trademarks. Prior to the first use of any of the other Party’s Trademarks in a manner permitted herein, the Party
using such Trademarks shall submit a sample of such proposed use to the other Party for its prior written approval. Without limiting the generality of the foregoing, each Party shall strictly comply with all standards with respect to the other
Party’s Trademarks which may be furnished by such Party from time to time, and all uses of the other Party’s Trademarks in proximity to the trade name, trademark, service name or service mark of any other Person shall be consistent with
the standards furnished by the other Party from time to time. Further, neither Party shall create a combination mark consisting of one or more Trademarks of each Party. All uses of the other Party’s Trademarks and goodwill therein shall inure
to the benefit of the Party owning such Trademark. Each Party hereby acknowledges and agrees that, as between the Parties, the other Party is the owner of the Trademarks identified as its Trademarks on Exhibit C. Either Party may update or change
the list of Trademarks usable by the other Party hereunder at any time by written notice to the other Party. Any materials, activities, products, or services distributed or marketed by a Party in conjunction with the other Party’s Marks shall:
(i) meet all terms of this Agreement, (ii) meet or exceed standards of quality and performance generally accepted in the telecommunications industry, and (iii) comply with all applicable laws, rules, and regulations. Each Party shall
fully correct and remedy any deficiencies in its use of the other Party’s Marks and/or the quality of any materials, activities, products, or services it offers or markets in conjunction with the other Party’s Marks, upon reasonable notice
from the other Party. 
 12.6 Copyright Notices. InfoSpace and Verizon Wireless acknowledge that the Portal Services may contain
copyright and patent notices of copyrighted or copyrightable works, including those of InfoSpace and its affiliates, Verizon Wireless and its affiliates, and Third Parties. 

12.7 Other Trademarks. InfoSpace shall not register or attempt to register any of the Verizon Wireless Marks or any Trademarks that Verizon
Wireless reasonably deems to be confusingly similar to any of the Verizon Wireless Marks. Verizon Wireless shall not register or attempt to register any of the InfoSpace Marks or any Trademarks that InfoSpace reasonably deems to be confusingly
similar to any of the InfoSpace Marks. 
 12.8 Further Assurances. Each Party shall take, at the other Party’s expense, such action
(including, without limitation, execution of affidavits or other documents) as the other Party may reasonably request to effect, perfect or confirm such other Party’s ownership interests and other rights as set forth in this Section 12.

 12.9 No Joint Development. The Parties contemplate that there will be no ad hoc joint development of Intellectual Property under this
Agreement. The Parties shall not engage in joint development except as they may separately agree, in writing, in advance. 
  

 PAGE 22 

	 	a.	In no event shall enhancements, adaptations, improvements, modifications and/or derivative works (“Enhancements”) created from one Party’s pre-existing
Intellectual Property be considered to be jointly owned by the Parties, regardless of which Party creates the Enhancement, it being understood that, subject to any licenses granted herein, such Enhancements shall be the sole and exclusive property
of the owner of the Intellectual Property upon which such Enhancements are based. 

 12.10 Ownership of Intellectual Property.

  

	 	a.	Any Intellectual Property now owned or subsequently developed by InfoSpace or its Third Party suppliers, that is offered for use as part of the Portal Services will
continue to be owned by InfoSpace. 

  

	 	b.	Any Intellectual Property now owned or subsequently developed by Verizon Wireless or its Third Party suppliers, that is offered for use as part of the Verizon Wireless
Services, the Verizon Wireless Network, and/or the Portal Services, will continue to be owned by Verizon Wireless. 

  

	 	c.	Neither Party shall attempt to register, with a state or federal agency, any Intellectual Property developed by the other Party, or its Third Party suppliers, that is
offered as part of the Portal Services. 

 12.11 Rights. Neither Party shall have any rights to any materials, content or
technology provided by the other Party hereunder, except as specifically provided in this Agreement, and neither shall alter, modify, copy, edit, format, translate, create derivative works of or otherwise use any materials, content or technology
provided by the other Party except as explicitly provided for herein, or as approved in advance, in writing, by the other Party. 
  

	 	a.	To the extent that InfoSpace provides Verizon Wireless with any written technical specifications or documentations with respect to the Portal Services, such
specifications are licensed to Verizon Wireless on a nonexclusive, non-assignable, non-sublicenseable basis, and may be used by Verizon Wireless solely for the purpose of providing input to InfoSpace (unless otherwise agreed to, in writing, by the
Parties). 

  

	 	b.	To the extent that Verizon Wireless provides InfoSpace with any written technical specifications or documentations with respect to the Verizon Wireless Network or the
Verizon Wireless Services (“Verizon Wireless Specifications”), such Verizon Wireless Specifications are licensed to InfoSpace on a nonexclusive, non-assignable, non-sub-licenseable basis, and may be used by InfoSpace solely for the purpose
of providing input to Verizon Wireless (unless otherwise agreed to, in writing, by the Parties). 

 12.12 Developed
Technology. The Parties contemplate that, from time-to-time, one Party may agree to develop Developed Technology for the other pursuant to a separate written agreement. The ownership and/or license rights in such Developed Technology,
compensation for its development, and other terms regarding Developed Technology shall be as set forth in such separate agreement. 
 12.13
Reservation of Rights. Each Party reserves all rights not expressly granted herein. 
  

 PAGE 23 

 12.14 Consumer Clear Disclosure/Spam. Except as otherwise set forth in this Agreement, InfoSpace
agrees that its collection, use and disclosure of Verizon Wireless User Data will comply with: (i) all applicable laws and regulations, and (ii) Verizon Wireless’ standard privacy policies, attached as Exhibit K. InfoSpace will not
disclose Verizon Wireless User Data collected hereunder to any Third Party in a manner that identifies Users or Verizon Wireless Users: (A) as end users of the Portal Services, (B) as users of Verizon Wireless products or services, or,
(C) unless with the consent of Users, as users of InfoSpace’s products or services. InfoSpace will not send, via SMS or WAP push, any Spam or advertising through the Verizon Wireless Network to any User absent Verizon Wireless’ prior
written approval. 
  

	13	Best Practices Guide 

 13.1 Use of Best
Practices Guide. InfoSpace hereby grants Verizon Wireless the right to use the InfoSpace Best Practices Guide (the “Guide”), attached hereto as Exhibit N, as may be updated by InfoSpace from time to time, for the limited purpose of
distributing portions or all of the Guide to Third Party content providers that will provide content via the Portal Services, subject to the following: 
  

	 	(a)	such use shall be non-exclusive; 

  

	 	(b)	Verizon Wireless’ use of the Guide shall be subject in all cases to the disclaimer set forth in Section 13.2 below and Verizon Wireless shall include a
substantially similar disclaimer within any document embodying all or portions of the Guide; and 

  

	 	(c)	 Verizon Wireless shall include the following attribution within any document embodying all or portions of the Guide: “portions
© [current year] InfoSpace.” 

13.2 Disclaimer. INFOSPACE DOES NOT WARRANT THAT THE INFORMATION CONTAINED IN THE GUIDE IS ERROR-FREE. INFOSPACE IS PROVIDING THE GUIDE TO YOU
“AS IS” AND “WITH ALL FAULTS.” INFOSPACE DOES NOT WARRANT, BY VIRTUE OF THIS DOCUMENT, OR BY ANY COURSE OF PERFORMANCE, COURSE OF DEALING, USAGE OF TRADE, OR ANY COLLATERAL DOCUMENT HEREUNDER OR OTHERWISE, AND HEREBY EXPRESSLY
DISCLAIMS, ANY REPRESENTATION OR WARRANTY OF ANY KIND WITH RESPECT TO THE GUIDE, INCLUDING, WITHOUT LIMITATION, ANY REPRESENTATION OR WARRANTY OF DESIGN, PERFORMANCE, MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, OR NON-INFRINGEMENT, OR ANY
REPRESENTATION OR WARRANTY THAT THE INFORMATION CONTAINED IN THE GUIDE IS APPLICABLE TO OR INTEROPERABLE WITH ANY SYSTEM, DATA, HARDWARE, OR SOFTWARE OF ANY KIND. ***. 

 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 24 

	14	Confidential Information 

 During the
course of this Agreement and the negotiation hereof, either Party may be given access to Confidential Information (orally, in hardcopy and/or electronic form) belonging to the other Party (the Disclosing Party”). In connection therewith, the
following shall apply: 
 14.1 The Party receiving the Confidential Information (the “Receiving Party”) shall not disclose any
Confidential Information to Third Parties for five (5) years following the date of its disclosure by the Disclosing Party to the Receiving Party, except to the Receiving Party’s consultants as provided for below. However, the Receiving
Party may disclose Confidential Information in accordance with judicial or other governmental order, provided the Receiving Party shall first give the Disclosing Party reasonable notice prior to making such disclosure, and shall comply with any
applicable protective order or equivalent, 
 14.2 The Parties agree to protect the Confidential Information of the other Party in the
same manner in which it protects its own proprietary and confidential information of like kind, but in no event, shall either Party exercise less than reasonable care in protecting the Confidential Information of the other Party, 

14.3 Access to Confidential Information shall be restricted to the Receiving Party’s employees, agents and contractors who have a need to
know and shall be subject to the confidentiality provisions of this Agreement. The Receiving Party shall take reasonable steps to ensure that all employees, agents and contractors are bound by the confidentiality provisions of this Agreement,

 14.4 Confidential Information may be disclosed, reproduced, summarized or distributed only in pursuit of the Receiving Party’s
business relationship with the Disclosing Party under the terms of this Agreement, 
 14.5 Receiving Party may not reverse engineer,
decompile or disassemble any software disclosed to Receiving Party, 
 14.6 All Confidential Information made available hereunder,
including copies and summaries thereof, shall be returned to the Disclosing Party or destroyed upon: (a) expiration or termination of this Agreement, or (b) request by the Disclosing Party, unless the Receiving Party is otherwise allowed
to retain such Confidential Information in accordance with this Agreement, 
 14.7 Nothing in this Agreement shall prohibit or limit
either Party’s use of information that: (a) was previously known to the Receiving Party, absent any obligation to maintain the confidentiality thereof, (b) was independently developed by or for the Receiving Party, provided that such
can be verified, (c) was acquired by the Receiving Party from a Third Party which is not, to the Receiving Party’s knowledge (after having made commercially reasonable inquiry thereof), under an obligation of confidence with respect to
such information, or (d) is or becomes publicly available through no breach of this Agreement, 
  

 PAGE 25 

 14.8 If either Party receives a subpoena or other validly issued administrative or judicial process
(“Notice to Produce”) requiring the production of the Confidential Information of the other Party, it shall provide prompt notice to the other of such receipt. The Party receiving the Notice to Produce shall thereafter be entitled to
comply with such Notice to Produce to the extent permitted by law without being in breach of this Agreement, 
 14.9 The Receiving Party
shall notify the Disclosing Party as soon as is reasonably possible under the circumstances, upon discovery of any unauthorized use or disclosure of Confidential Information, and will cooperate with the Disclosing Party in every reasonable way to
help the Disclosing Party regain possession of the Confidential Information and prevent its further unauthorized use, 
 14.10 All
information which a Disclosing Party discloses to a Receiving Party and which is to be protected hereunder as Confidential Information, shall: (a) if disclosed in writing or in some other tangible form, be conspicuously labeled as Proprietary,
Confidential, or the like, at the time of delivery, and (b) if disclosed orally, be identified as being Proprietary, Confidential, or the like, prior to or following disclosure. Either Party shall have the right to correct any inadvertent
failure to designate information as Confidential Information by written notification, as soon as practical after disclosure is made, but in any event, no later than sixty (60) days after such error is determined. The Party receiving said
notification shall, from that time forward, and to the extent said Confidential Information is not in the public domain, treat such information as Confidential under the terms of this Agreement, and 

14.11 The terms of confidentiality under this Agreement shall not be construed to limit either Party’s right to independently develop or
acquire products without use of the other Party’s Confidential Information. 
  

	15	Miscellaneous 

 15.1 Publicity.
Except for legally mandated disclosures or rules of the applicable stock exchanges on which the securities of the Parties are traded, no Party shall issue any press release or make any public announcement(s) disclosing the terms or the existence of
this Agreement without the prior written consent of the other Party. 
  

	 	a.	The Parties agree to issue, promptly upon the launch of the Portal Services, a joint press release announcing the launch of the Portal Services and mutually agreed upon
publicity and general marketing communications concerning their relationship and other mutually agreed upon matters. Neither Party shall issue any other such publicity or general marketing communications concerning their relationship without prior
written consent of the other Party. 

 15.2 Independent Contractors. Verizon Wireless and InfoSpace are independent
contractors under this Agreement, and nothing herein shall be construed to create a partnership, joint venture, franchise, agency or relationship of any other kind between Verizon Wireless and InfoSpace. Neither Party has any authority to enter into
agreements of any kind on behalf of the other Party, and neither Party will attempt to or create any license, warranty or other obligation, express or implied, on behalf of the other Party or any of its Affiliates. 

 

 PAGE 26 

 15.3 Professionalism. InfoSpace shall remove from the work, at Verizon Wireless’ request,
any employee furnished by InfoSpace who, in Verizon Wireless’ opinion is incapable, uncooperative, or otherwise unacceptable in the execution of the work to be performed under this Agreement. 

15.4 Assignment; Merger. Neither Party may assign this Agreement or any of its rights or delegate any of its duties under this Agreement without
the prior written consent of the other Party, not to be unreasonably withheld. Notwithstanding the foregoing, either Party may assign this Agreement, without the other Party’s consent, to its parent company or to any purchaser of all or
substantially all of such Party’s assets, or to any successor by way of merger, consolidation or similar transaction. Subject to the foregoing, this Agreement will be binding upon, enforceable by, and inure to the benefit of the Parties and
their respective parents, successors, assigns, affiliates and future  
 15.5 Choice of Law. This Agreement shall be
governed by, and construed in accordance with, the laws of the State of Delaware, without reference to its choice of law rules.  

15.6 Dispute Resolution. 
  

	 	(a)	Arbitration. Any controversy or claim arising out of or relating to this Agreement, or the breach, termination or validity thereof, shall be settled by a sole
arbitrator in accordance with the CPR Non-Administered Arbitration Rules. The arbitration shall be governed by the United States Arbitration Act, 9 U.S.C. 1-16, and judgment upon the award rendered by the Arbitrators may be entered by any court
having jurisdiction thereof. The place of the arbitration shall be New York, New York. Punitive and exemplary damages shall not be awarded. Process may be served on either party by U.S. Mail, postage prepaid, certified or registered, return receipt
requested, or by such other method as is authorized by law. Notwithstanding the foregoing, each Party may institute formal proceedings at any time with a court of competent jurisdiction to avoid the expiration of any applicable limitations period,
to preserve a superior position with respect to other creditors, or as provided in 15.6(b) (“Injunctive Relief”) below. 

  

	 	(b)	Injunctive Relief. Notwithstanding the dispute resolution process set forth in Section 15.6(a) above, if (i) a Party determines that a breach (or
potential breach) of the terms of this Agreement by the other Party may result in damages or consequences that would be immediate, severe and incapable of adequate redress after the fact, so that a temporary restraining order or other immediate
injunctive relief is the only adequate remedy; or (ii) a Third Party necessary to the resolution of any dispute cannot be joined in the arbitration proceedings, that Party may institute proceedings for appropriate equitable relief in a court of
competent jurisdiction. 

 15.7 Nonwaiver. No waiver of any breach of any provision of this Agreement shall constitute a
waiver of any prior, concurrent or subsequent breach of the same or any other provisions hereof, and no waiver shall be effective unless made in writing and signed by an authorized representative of the waiving Party. 

 

 PAGE 27 

 15.8 Force Majeure. Neither Party shall be deemed to be in default of or to have breached any
provision of this Agreement as a result of any delay, failure in performance or interruption of service, resulting directly or indirectly from acts of God, acts of civil or military authorities, civil disturbances, terrorism, wars, strikes or other
labor disputes, fires, flood, storm, explosions, or any other cause which is beyond the reasonable control of such Party and such causes a Party to be unable to perform hereunder, resulting in a material or adverse effect on this Agreement, and
provided that such Party makes reasonable efforts to promptly remedy the failure or delay when such cause is eliminated. If a Party’s failure or delay of performance is excused by this Section for thirty (30) days or more, the other Party
may, but shall not be obligated to, immediately terminate this Agreement upon written notice to the non-performing Party. 
 15.9
Notices. Any notice or other communication required or permitted to be given hereunder shall be given in writing and delivered in person, mailed via confirmed facsimile or e-mail, or delivered by recognized courier service, properly addressed
and stamped with the required postage, to the applicable Party at its address specified below and shall be deemed effective upon receipt. Either Party may from time to time change the individual to receive notices or its address by giving the other
Party notice of the change in accordance with this section. 
 To Verizon Wireless: 

Notices To Verizon Wireless: 
 Verizon
Wireless 
 Address: 180 Washington Valley Road 

Address: Bedminster, New Jersey 07921 
 Attn.:
***, Executive Vice President and Chief Technical Officer 
 Fax: *** 

Copy to: 
 ***, 

Associate General Counsel 
 Sales, Marketing and

 Consumer Law 
 30 Independence Blvd

 Warren, New Jersey 07059 
 Telephone:
*** 
 Fax: *** 
 Email Address:
*** 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 28 

 To InfoSpace: 

Premium Wireless Services USA, Inc. 

10940 Wilshire Blvd.,
9th Floor 

Los Angeles, CA 90024 
 Fax: *** 

Attention: Legal Department              Attention: EVP - Wireless 

with a copy to: 
 Premium Wireless Services
USA, Inc. 
 10940 Wilshire Blvd.,
9th Floor 

Los Angeles, CA 90024 
 Fax: *** 

Attention: VP – Legal Affairs 
 15.10
Savings. In the event any provision of this Agreement shall for any reason be held to be invalid, illegal or unenforceable in any respect, the remaining provisions shall remain in full force and effect. If any provision of this Agreement
shall, for any reason, be determined by a court of competent jurisdiction to be excessively broad or unreasonable as to scope or subject, such provision shall be enforced to the extent necessary to be reasonable under the circumstances and
consistent with applicable law while reflecting as closely as possible the intent of the Parties as expressed herein. 
 15.11
Integration. This Agreement contains the entire understanding of the Parties hereto with respect to the transactions and matters contemplated hereby, it supersedes all previous agreements or negotiations between InfoSpace and Verizon Wireless
concerning the subject matter hereof, and it cannot be amended except by a writing signed by both Parties. 
 15.12 Counterparts;
Electronic Signature. This Agreement may be executed in counterparts, each of which will be deemed an original, and all of which together constitute one and the same instrument. 

15.13 PLANT AND WORK RULES AND RIGHT OF ACCESS 

15.13.1. Anyone acting on behalf of one Party, while on the premises of the other, shall comply with all plant rules, regulations and
premises owner’s standards for security, including (when required by U.S. government regulations) submission of satisfactory clearance from U.S. Department of Defense and other federal authorities concerned. 

15.13.2. Each Party shall permit reasonable access during normal working hours to its facilities in connection with the Portal Services.
Reasonable prior notice shall be given when access is required. 
 15.13.3. InfoSpace shall provide, upon reasonable advance
notice from Verizon Wireless, its employees, subcontractors, and agents and work vehicles with identification in accordance with current Verizon Wireless requirements. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 29 

 15.13.4. If InfoSpace is given access, whether on-site or through remote facilities, to any
Verizon Wireless computer or electronic data storage system in order for InfoSpace to accomplish the Portal Services called for in this Agreement, InfoSpace shall limit such access and use solely to perform Portal Services within the scope of this
Agreement and shall not access or attempt to access any computer system, electronic file, software or other electronic services other than those specifically required to accomplish the work required under this Agreement. InfoSpace shall limit such
access to those of its employees who are authorized by Verizon Wireless to have such access in connection with this Agreement, and shall follow all Verizon Wireless’ reasonable security rules and procedures for use of Verizon Wireless’
electronic resources, provided that such rules and procedures are furnished to InfoSpace at the time of such access or in advance. All user identification numbers and passwords disclosed to InfoSpace and any information obtained by InfoSpace as a
result of InfoSpace’s access to and use of Verizon Wireless’ computer and electronic data storage systems shall be deemed to be, and shall be treated as, Verizon Wireless Confidential Information under applicable provisions of this
Agreement. Verizon Wireless reserves the right to monitor such actions by InfoSpace and InfoSpace agrees to cooperate with Verizon Wireless in the investigation of any apparent unauthorized access by InfoSpace to Verizon Wireless’ computer or
electronic data storage systems or unauthorized release of Verizon Wireless’ Confidential Information by InfoSpace. 
 15.14
Insurance. 
 15.14.1 As of the Effective Date and throughout the Term, InfoSpace shall maintain the insurance coverage set
forth below: 
  

	 	a.	Worker’s Compensation and related insurance as prescribed by the law of the state in which the work is performed; 

 

	 	b.	Employer’s liability insurance with limits of at least ***; 

  

	 	c.	Professional Liability (Errors and Omissions) covering services and/or intellectual property risks of copyright, trademark and patent infringement with limits of not
less than ***; and 

  

	 	d.	Commercial general liability insurance (including, but not limited to, premises operations, broad-form property damage, products/completed operations, contractual
liability, independent contractors, personal injury) and, if the use of automobiles is required, comprehensive automobile liability insurance, each with limits of at least ***. 

The limits above may be satisfied through a combination of primary and/or umbrella excess coverage. 

15.14.2 The insuring carriers shall be rated at least A- by AM Best. Such policies shall be primary and non-contributory by Verizon
Wireless. Verizon Wireless shall be named as an additional insured on all liability policies in Section 15.14.1 (d). InfoSpace shall furnish to Verizon 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 30 

 
Wireless certificates of such insurance within ten (10) days of the execution of this Agreement and with each policy renewal. The certificates shall provide that at least ten (10) days
prior written notice of cancellation or material change of the insurance to which the certificates relate shall be given to Verizon Wireless. The fulfillment of the obligations hereunder in no way modifies InfoSpace’s obligations to indemnify
Verizon Wireless under this Agreement. 
 15.15 NO COMPETITOR ADVERTISING 

The Parties agree that InfoSpace shall not be entitled to advertise via the Portal Services, nor shall it place advertisements of third parties on the
Portal Services without written consent of Verizon Wireless. 
 15.16 Subcontracting. InfoSpace shall not, without the prior written
consent of Verizon Wireless, subcontract to a Third Party any material portion of the Service provided under this Agreement. 
 15.17
Post Execution Cooperation. At any time, and from time-to-time within the thirty (30) day period following the Effective Date, the Parties agree to cooperate in good faith to amend and/or amend and restate this Agreement, including all
Exhibits and attachments, (in each case, in writing, signed by both Parties) as may be necessary in order toensure that the provisions hereof are internally consistent, do not conflict with any other provisions hereof, that the section references
are accurate, and that this Agreement otherwise accurately reflects the agreement of the Parties. Within thirty (30) calendar days of the Effective Date the Parties shall develop Exhibit L, Content Hosting and update Exhibit F-1, Service Level
Agreement, which will include provisions for the service level requirements related to the interfaces described in Exhibits B and J. If said exhibits are not developed within said thirty (30) days, the Parties shall use the escalation process
outlined in Section 10.4 of the Agreement for resolution. 
 15.18 Entire Agreement. The terms and provisions herein
contained constitute the entire understanding between the Parties with regard to the terms hereof, the Exhibits hereto and the SLA, and shall supersede all previous communications, whether oral or written, and no agreements or understandings varying
or extending this Agreement, the Exhibits hereto or the SLA shall be binding upon any Party hereto unless agreed to in writing and signed by a duly authorized officer or representative thereof. This Agreement is specifically intended to terminate
and supercede the Letter Agreement between the Parties dated March 2, 2004. 
  

	 	a.	Should the Federal Communications Commission (“FCC”) or any state or federal law, render any opinion, term, covenant, restriction, representation or warranty
of this Agreement to be illegal, void or unenforceable, in whole or in part, the Parties agree to enter into good faith negotiations designed to resolve any discrepancy (whether a business or legal issue) which may have arisen as a result of the
court’s order, and/or to fill any gap in the contract (again, whether business or legal) which the court order or change in law may have brought about. 

  

 PAGE 31 

 15.19 Testimony. Matters relating to this Agreement may be in issue before various regulatory bodies.
InfoSpace, including senior members of its firm, agrees to have appropriate members of its firm available to testify at reasonably appropriate times and for reasonable fees, at Verizon Wireless’ sole cost and expense, regarding any material
aspect of this Agreement as known to InfoSpace or its employees. Nothing set forth in this Section 15.19 shall restrict or prohibit InfoSpace or any of its agents or employees from asserting applicable claims of confidentiality, trade secrets
or legal privilege. 
 15.20 InfoSpace, Inc. Premium Wireless Services USA, Inc. is a subsidiary of InfoSpace, Inc. To the extent that
Premium Wireless Services USA, Inc. is unable or unwilling to fulfill its obligations under this Agreement, InfoSpace, Inc. agrees to fulfill such obligations on Premium Wireless Services USA, Inc.’s behalf. 

IN WITNESS WHEREOF, the Parties have duly executed and delivered this Agreement as of the Effective Date. 

 

					
	Cellco Partnership d/b/a Verizon Wireless	 		 	Premium Wireless Services USA, Inc.
			
	***	 		 	***
	By (signature)	 		 	By (signature)
			
	***	 		 	***
	Name	 		 	Name
			
	President & CEO	 		 	President
	Title	 		 	Title
			
		 		 	InfoSpace, Inc.
			
		 		 	***
		 		 	By (signature)
			
		 		 	***
		 		 	Name
			
		 		 	CAO
		 		 	Title

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 32 

 LIST OF EXHIBITS 

Exhibit A – Definitions 
 Exhibit B –
Portal Services 
 Exhibit C – Trademarks 

Exhibit D – Commercial Terms 
 Exhibit E
– Form of Work Order 
 Exhibit F – Modalyst System Diagram 

Exhibit G – Training 
 Exhibit H –
Service Level Agreement 
 Exhibit I – Acceptance Test Plan 

Exhibit J – Statement of Work and Reporting 

Exhibit K – Verizon Wireless Privacy Policy 

Exhibit L – Content Hosting 
 Exhibit M
– Intentionally omitted 
 Exhibit N – InfoSpace Best Practices Guide 

Exhibit O – InfoSpace Computing Security Policy 

Exhibit P – Application Validation Process 
  

 PAGE 33 

 EXHIBIT A 

DEFINITIONS 
 1.
“Adult Content” shall mean any obscene, profane, pornographic, sexually suggestive or nude content. 
 2.
“Adverse Impact” shall mean a Verizon Wireless Network circuit-switched outage (excluding any outages for scheduled maintenance) that lasts *** within a particular Verizon Wireless market (i.e., a Metropolitan Service Area or Rural
Service Area as designated by the Federal Communications Commission), and that is caused by the Portal Services. 
 3.
“Affiliate” shall mean, with respect to a Party to this Agreement, any Person, that directly or indirectly, through one or more intermediaries, controls, is controlled by or is under common control with such Party to this
Agreement. For purposes of this definition, “control” when used with respect to any specified Person means the power to direct the management and policies of such Person, directly or indirectly, or has ownership of at least ten percent
(10%) of the voting securities of such Person. 
 4. “Aggregate Information” shall mean usage data or other
information about multiple Users that does not contain Personally Identifiable Information. 
 5. “Commercial Mobile Radio
Service” (“CMRS”) shall mean a radio service in which common carriers are, as of the Effective Date, authorized by the Federal Communications Commission under the Code of Federal Regulations (CFR) Title 47, Part 22 and licensed
under CFR Title 47, Part 22, Subpart H, to offer and provide service for hire to the general public through a cellular system utilizing the channels and frequency bandwidths assigned under CFR Title 47, Part 22, Subpart H, Section 22.905.

 6. “Commercial Service Date” means the earlier of: (i) June 25, 2004, or (ii) the date of Verizon
Wireless’ written acceptance of the Portal Services in accordance with Section 1(b) of Exhibit D. 
 7. “Confidential
Information” shall mean nonpublic information (in whatever form), that the disclosing Party designates as being confidential or which, under reasonable circumstances surrounding disclosure would be treated as confidential.
“Confidential Information” includes, but is not limited to specifications, drawings, sketches, models, samples, reports, plans, forecasts, current or historical data, computer programs, documentation, market research, market plans,
business plans, information relating to released or unreleased disclosing Party products or services, information relating to the marketing or promotion of any disclosing Party product or service, the disclosing Party’s business policies or
practices, information received from others that the disclosing Party knows it is obligated to treat as confidential, and all other nonpublic, technical, financial or business data, which is disclosed to one Party hereunder by the other Party.
Confidential Information shall not include any information that: (a) is or subsequently becomes publicly available without the receiving Party’s breach of any obligation owed to the disclosing Party, (b) became known to the receiving
Party prior to the disclosing Party’s disclosure of such 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 34 

 
information to the receiving Party, provided such can be verified, (c) became known to the receiving Party from a source other than the disclosing Party other than by the breach of an
obligation of confidentiality owed to the disclosing Party, provided such can be verified, or (d) is independently developed by the receiving Party, provided such can be verified. Confidential Information disclosed to the receiving Party by any
disclosing Party Affiliate and/or agents shall be considered Confidential Information under the terms of this Agreement and in accordance with this definition. 

8. “Effective Date” shall mean the last date upon which this Agreement is signed by both Parties. 

9. “Electronically Transmitted Information” shall mean all information exchanged between the Parties by means of electronic
transfer as per the terms of this Agreement, as well as any service that either Party may provide to the other Party under this Agreement by means of electronic transfer, including the media upon which the information is stored or from which the
service is rendered. 
 10. “Implementation Schedule” means a schedule for the development and delivery of the Portal
Services, to be mutually agreed upon by the Parties, in writing, including milestones to be met by each Party in connection with the development and delivery of the Portal Services. 

11. “InfoSpace Marks” means those Trademarks of InfoSpace set forth on Exhibit C hereto and such other Trademarks (if any) as
InfoSpace may from time to time notify Verizon Wireless in writing to be “InfoSpace Marks” within the meaning of this Agreement. 

12. “InfoSpace Pages” means the “PC Pages” and the “Phone Pages.” 

13. “Intellectual Property” shall mean: (a) copyright rights (including, without limitation, the exclusive right to use,
reproduce, modify, distribute, publicly display and publicly perform the copyrighted work), (b) trademark rights (including, without limitation trade names, trademarks, service marks, and trade dress), (c) patent rights (including, without
limitation, the exclusive right to make, use, offer to sell, and sell, (d) trade secrets, (e) moral rights, (f) inventions, (g) software applications, and (h) software rights, as such rights arise under the laws of the
United States. 
 15. “Intellectual Property Rights” means any patent, copyright, rights in Trademark, trade secret, moral
right, mask work and any other intellectual property or proprietary right of any kind, whether arising under the laws of the United States or any other nation, state or jurisdiction. 

16. “Mobile Virtual Network Operator” shall mean a Person that offers CMRS services to customers, including its own mobile network code,
SIM card, and mobile switching center, but does not necessarily own the radio frequency (spectrum) allocation on which it operates. 
 17.
“Page View” means a display of a Phone Page on a Wireless Device. 
 18. “PC” means a personal computer.

 19. “PC Pages” means web pages that are hosted by InfoSpace and prepared using HTML and intended for presentation to Users
using PCs as their display device. 
  

 PAGE 35 

 20. “Person” means any natural/individual person, corporation, subsidiary, partnership,
co-partnership, limited liability company, firm, joint venture, association, joint stock company, trust, estate, unincorporated organization, or other entity, however organized. 

21. “Personally Identifiable Information” shall mean: (a) information about a User that identifies him or her as a unique
individual (e.g., stating his or her name, credit card number, social security number, user ID, or electronic serial number), or (b) contact information identifying the User as a unique individual (e.g., his or her phone number, mobile
directory number, physical address, email address or alias email address). 
 22. “Phone Pages” means web pages that are
hosted by InfoSpace and prepared using XHTML and intended for presentation to Users using Wireless Devices as their display device. 
 27.
“Portal Services” means the products and services that will be made available to Verizon Wireless by InfoSpace as set forth in this Agreement and pursuant to the specifications of Exhibit B. 

23. “Premium Content” means content accessible to Users via the Verizon Wireless Services for which InfoSpace provides authorization
services via Subscription Manager as described in Section A(1)(b) of Exhibit B. 
 24. “Project” shall mean the work required
by and the cooperation anticipated between the Parties under the terms and conditions of this Agreement. 
 25. “Retail Revenue”
means all subscription revenue generated by Verizon Wireless from Premium Content. 
 26. “Self-Help Code” means any back
door, “time bomb,” drop dead device, or other software routine intentionally designed to disable a computer program automatically with the passage of time or under the positive control of a person other than an owner or licensee of the
program. Self-Help Code does not include software routines in a computer program, if any, designed to permit the owner or licensor of the computer program (or other person acting by authority of the owner or licensor) to obtain access to a
licensee’s computer system(s) (e.g., remote access via modem) for purposes of maintenance or technical support. 
 28. “Statement
of Work” means functional requirements for the Portal Services to be mutually agreed upon, in writing, by the Parties. 
 29.
“Technology” means any know-how, graphics, techniques, methods, formulae, drawings, designs, source code, concepts, ideas, documentation, or any improvement or upgrade thereto, whether or not patentable or copyrightable and whether or
not reduced to practice related to or used by or on behalf of InfoSpace or any of its affiliates in connection with the Portal Services or any portion thereof or to provide access to the Services. 

30. “Term” shall mean the period of time from the Effective Date until the termination or expiration of this Agreement, including any
renewal and transition periods, as stated in Section 8.1. 
 31. “Territory” shall mean the United States of America.

 32. “Third Party” means any Person not a Party to this Agreement. 

 

 PAGE 36 

 33. “Trademarks” means trademarks, service marks, trade names, proprietary logos or
indicia, and other source or business identifiers. 
 34. “Unauthorized Code” shall mean any virus, Trojan horse, worm, or any
other software routines or hardware components intentionally designed to permit unauthorized access, to disable, erase, or otherwise harm software, hardware, or data, or to perform any other such actions. The term Unauthorized Code does not include
Self-Help Code. 
 35. “User” means any customer of Verizon Wireless that is authorized by Verizon Wireless to access the
Verizon Wireless Services. 
 36. “User Data” means all information, whether Aggregate Information or Personally Identifiable
Information (including, but not limited to the MIN and the MDN), generated or collected by or for Verizon Wireless: (a) under the terms of any Verizon Wireless customer agreement, (b) in connection with a Verizon Wireless User’s use
of the Verizon Wireless Services and/or the Portal Services, and/or (c) under stand-alone terms and conditions, the terms and conditions of a Verizon Wireless customer agreement or under a similar agreement. 

37. “Verizon Wireless Competitor” shall mean any mobile network operator or any Mobile Virtual Network Operator. 

38. “Verizon Wireless Content” means any content owned or licensed by Verizon Wireless that Verizon Wireless provides to InfoSpace for
use in connection with the Portal Services. 
 39. “Verizon Wireless Marks” means those Trademarks of Verizon Wireless set
forth on Exhibit C hereto and such other Trademarks (if any) as Verizon Wireless may from time to time notify InfoSpace in writing to be “Verizon Wireless Marks” within the meaning of this Agreement. 

40. “Verizon Wireless Materials” means the Verizon Wireless Marks and any other graphical or other content, specifications or materials,
including, without limitation: (a) user interface design components, owned or licensed by Verizon Wireless and supplied by Verizon Wireless to InfoSpace for inclusion in the Portal Services, and (b) any applications, technologies or
services owned or licensed by Verizon Wireless and supplied by Verizon Wireless to InfoSpace for inclusion in the Portal Services. 
 41.
“Verizon Wireless Network” shall mean the CMRS switching equipment, cell site transceiver equipment and other equipment and systems which are owned, operated and/or managed by Verizon Wireless for the provision of the Verizon Wireless
Services in any part of the Territory in which Verizon Wireless is licensed by the FCC to provide the Verizon Wireless Services, and as may be configured and reconfigured at anytime and from time-to-time by Verizon Wireless in its sole discretion.

 42. “Verizon Wireless Services” shall mean the package of wireless network services offered by Verizon Wireless (which may
change from time-to-time at the sole discretion of Verizon Wireless), including the Verizon Wireless Network, that, among other things, enables voice and/or data Verizon Wireless Users to access the Portal Services via a Wireless Device. 

 

 PAGE 37 

 43. “Virus” shall mean disabling or Unauthorized Code, Self Help Code or other software
routines designed to cause data or information, systems or applications, or any portion thereof, and without the control of the user thereof: (a) to become lost or erased, (b) to become inoperable, or (c) to operate in an unauthorized
manner. 
 44. “Wireless Device” means those devices supported in accordance with the technical specifications set forth in
this Agreement that contain a WAP 2.0 browser as referenced in Section B of Exhibit B, plus any new devices the Parties may agree upon in the future. 
  

 PAGE 38 

 EXHIBIT B 

PORTAL SERVICES 
  

	A.	Description of Portal Services. 

 Subject
to the terms and conditions of this Agreement, InfoSpace will, in cooperation with Verizon Wireless, design, develop, implement, host and maintain the Portal Services. Verizon Wireless will design and supply the graphical content and Verizon
Wireless Marks to be used in connection with the Portal Services, and InfoSpace will be responsible for implementing the graphical user interface and related design elements for the Portal Services. 

*** 
 As between the Parties, Verizon Wireless
shall be solely responsible for: (i) setting and collecting fees from Users for access to the Portal Services, and (ii) direct communications with Users regarding telecommunications services enabling InfoSpace to provide the Portal
Services. 
 The Portal Services will be comprised of the following Content Management Tools and Hosting Services: 

 

	B.	Content Management Tools 

(a) *** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 39 

 *** 
  

	1.	Hosting Services 

 ***

  
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 40 

 *** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 41 

 
*** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 42 

 ***. 
  

	C.	Wireless Devices Supported. 

 1. InfoSpace
will optimize the Portal Services for presentation on the following Wireless Devices, *** 
 Throughout the contract period InfoSpace will
continue to optimize the Portal Services for each new Wireless Device that Verizon Wireless makes available to end customers on a commercial basis. ***. 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 43 

 *** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 44 

 EXHIBIT C 

TRADEMARKS 

Verizon Wireless Marks 
 Verizon
Wireless reserves any and all intellectual property rights that it has established in any of its product, feature or service names or logos, even if such name or logo does not appear on this list. 

 

 

 InfoSpace Marks 

InfoSpace reserves any and all intellectual property rights that it has established in any of its product, feature or service names or logos, even if such
name or logo does not appear on this list. 

100Hot®
 

ActiveShopper®
 

AdfocusTM
 

AirPayTM
 

AprilFools.com®
 

AudiocubTM
 

Authorize.Net®
 

Authorize.Net®
 Where the World Transacts 

 

 

 Authorize.Net Where the World Does Business on the Web &
Design® 

Classifieds2000®
 

CoolNotify®
 
  

 PAGE 45 

 Discover What You Can
DoTM 

Dogpile®
 
 Dogpile
(Stylized)® 

 

 

E-Cash®
 

eCheck.Net®
 

E-Vote®
 

EZStoreTM
 

Fraudscreen.Net®
 
 Giant
BearTM 

 

 

Giantbear.com®
 

Go2Net®
 
 Go2Net (&
Design)SM 

 

 

 Haggle
Online® 

HyperMart®
 

InfoSpace®
 
 InfoSpace (&
Design)® 

 

 

 InfoSpace
XGTM 

InfoSpace Mobile
ZoneTM 

IntelliShopper®
 

Jango®
 

Kidcash®
 

MetaCrawler®
 

MetaSpy®
 

MobilezoneTM
 

MyAgent®
 

PageGreetings®
 
 Pocket
Authorize.Net® 

Powered by
InfoSpace® 

RubberChicken.com®
 

SaraideTM
 
  

 PAGE 46 

 Search the Search
Engines!® 

SyncnowTM
 

Valentine.com®
 
 Virtual Avenue Free Virtual Domain Hosting (&
Design)® 

 

 

 Virtual
Outlet® 

WAM!TM
 

WebMarket®
 
 Web 21 
 Webcrawler

©
 2004 InfoSpace, Inc. 
 All rights not expressly granted herein are reserved. 

 

 PAGE 47 

 EXHIBIT D 

COMMERCIAL TERMS 
 ***

  
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 48 

 *** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 49 

 *** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 50 

 EXHIBIT E 

FORM OF WORK ORDER 

Work Order No.              

to WAP 2.0 Hosting Agreement 

Premium Wireless Services USA, Inc. (“InfoSpace”) will perform the following additional services for
                             (“Verizon Wireless”) under the terms and conditions of that
certain WAP 2.0 Hosting Agreement, Contract No. 750-67761-2004, dated
                                 between InfoSpace and Verizon Wireless. In
consideration of the additional services described below, Verizon Wireless will pay to InfoSpace the amount(s) set forth below on or before the date(s) set forth below. 

 

			
	 Task Description
	  	Target Date
		  	
		  	
	 Amount
	  	Due Date
		  	
		  	

  

					
	Verizon Wireless	 		 	Premium Wireless Services USA, Inc.
			
	  	 		 	  
	By (signature)	 		 	By (signature)
			
	  	 		 	  
	Name	 		 	Name
			
	  	 		 	  
	Title	 		 	Title

  

 PAGE 51 

 EXHIBIT F 

MODALYST SYSTEM DIAGRAM 

*** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 52 

 EXHIBIT G 

TRAINING 
 1.
InfoSpace Training. InfoSpace will provide its standard training and documentation to Verizon Wireless employees as listed in the following table: 

*** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 53 

 EXHIBIT H 

SERVICE LEVEL AGREEMENT 

The Service Level Agreement is attached here to as Exhibit H-1 and shall be updated within thirty (30) calendar days of the Effective Date to
include provisions for the service level requirements related to the interfaces described in Exhibits B and J. If the service level requirements are not developed and agreed to after said thirty (30) days, the Parties shall use the escalation
process outlined in Section 10.4 of the Agreement for resolution. 
  

 PAGE 54 

 EXHIBIT I 

ACCEPTANCE TEST PLAN 

*** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 55 

 EXHIBIT J 

STATEMENT OF WORK 
 ***

  
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 56 

 EXHIBIT K 

VERIZON WIRELESS PRIVACY POLICY 

Verizon Wireless’ Privacy Policy is attached hereto as Exhibit K-1, which may be modified by Verizon Wireless from time to time. 

 

 PAGE 57 

 EXHIBIT L 

CONTENT HOSTING 
 This
Content Hosting exhibit shall be developed and agreed to by both Parties within thirty (30) calendar days of the Effective Date. If the exhibit is not developed and agreed to after said thirty (30) days, the Parties shall use the
escalation process outlined in Section 10.4 of the Agreement for resolution. 
  

 PAGE 58 

 EXHIBIT M 

Intentionally omitted. 
  

 PAGE 59 

 EXHIBIT N 

INFOSPACE BEST PRACTICES GUIDE 

InfoSpace’s Best Practices Guide is attached hereto as Exhibit N-1. This Guide may be updated from time to time by InfoSpace. 

 

 PAGE 60 

 EXHIBIT O 

INFOSPACE SECURITY POLICY 

*** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 61 

 EXHIBIT P 

APPLICATION VALIDATION PROCESS 

*** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 PAGE 62 

 Verizon Wireless 

WAP 2.0 Portal Services 

Service Level Agreement 

June, 2004 
 This
document contains confidential information. No part of this document may be reproduced in 
 any form without the written consent
of Verizon Wireless. Information in this document is for 
 use by Verizon Wireless, its employees, and customers under license
only. 
  

 Page i 

 Verizon Wireless WAP 2.0 Service Level Agreement 

Table of Contents 
  

							
	 1
	  	Overview	  	1
		  	1.1	  	Introduction	  	1
		  	1.2	  	Referenced Documents	  	1
		  	1.3	  	Purpose and Scope	  	1
		  	1.4	  	Products and Services	  	1
		  	1.5	  	Definitions	  	2
			
	 2
	  	Roles and Responsibilities	  	4
		  	2.1	  	Overview	  	4
		  	2.2	  	Stakeholders	  	4
		  	2.3	  	Role Assignments	  	4
			
	 3
	  	Service Availability, Service Performance and Response/Restore Times	  	6
		  	3.1	  	Overview	  	6
		  	3.2	  	Service Availability Metrics	  	6
		  	3.3	  	Service Performance Metrics	  	6
		  	3.4	  	Response/Restore Times	  	7
		  	3.5	  	Service Availability Requirements	  	7
		  	3.6	  	Service Performance Requirements	  	7
		  	3.7	  	Response and Restore Time Requirements	  	7
			
	 4
	  	Credits	  	7
		  	4.1	  	Service Availability	  	7
		  	4.2	  	Service Performance	  	8
		  	4.3	  	***	  	8
		  	4.4	  	Cumulative Maximum Monthly Credit	  	8
			
	 5
	  	Incident Management	  	9
		  	5.1	  	InfoSpace Carrier Care	  	9
		  	5.2	  	Incident Response	  	9
		  	5.3	  	Incident Notification Process	  	15
			
	 6
	  	InfoSpace Generated Reports	  	16
		  	6.1	  	Post Incident Review Reports	  	16
		  	6.2	  	Service Level Reporting	  	16
		  	6.3	  	Open Issues List Reporting	  	17
			
	 7
	  	Change Management	  	17
		  	7.1	  	InfoSpace Changes & Maintenance	  	17
		  	7.2	  	Capacity Planning Forecasts	  	18
		  	7.3	  	Verizon Wireless Changes	  	18

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page i 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

			
	 Appendix A – Support Contact & Escalation List
	  	20
		
	 Appendix B – WAP 2.0 End Device List
	  	22

  

 Page ii 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

 List of Tables 
  

			
	 Table 1 – Scope of Products and Services
	  	1
	 Table 2 – RACI Model
	  	4
	 Table 3 – Roles and Responsibilities
	  	5
	 Table 4 – Service Availability Requirements
	  	7
	 Table 5 – Service Performance Requirements
	  	7

  

 Page iii 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

	1	Overview 

  

	1.1	Introduction 

 This Service Level Agreement (SLA)
defines the services to be provided by InfoSpace in its support of Verizon Wireless’ WAP 2.0 portal. Additional details include performance targets, measurements, reports, processes, roles, and responsibilities required to achieve mutually
agreed upon service level targets. 
  

	1.2	Referenced Documents 

 The following documents
are referenced by this document: 
 *** 
  

	1.3	Purpose and Scope 

 This SLA sets forth the terms
agreed to between InfoSpace and Verizon Wireless with respect to the basic level of service that InfoSpace and Verizon Wireless will provide in order to support the delivery of services to Users contemplated in the Agreement. This includes the
following: 
  

	 	•	 	 Definitions 

  

	 	•	 	 Roles and Responsibility 

  

	 	•	 	 Service Availability, Service Performance and Response/Restore Times 

 

	 	•	 	 Credits 

  

	 	•	 	 Incident Management & Service Restoration 

  

	 	•	 	 Change Management and Maintenance 

  

	 	•	 	 Contact and Escalation Information 

  

	1.4	Products and Services 

 The scope of this SLA
encompasses the products and services listed below in Table 1, designed to support Verizon Wireless’ WAP 2.0 portal and related services. The intent of this SLA is to define services, reports, processes, roles, and responsibilities designed to
meet service level targets and user expectations. 
 *** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 1 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

	1.5	Definitions 

 “Available Time in
Month” means the total number of days in the month times 1,440 minutes. 
 “Defect” *** 

“InfoSpace’s Span of Control” *** 

“Response” means the Vendor’s engineer or technician has contacted Verizon Wireless regarding the applicable request for assistance
with respect to a defect. The response time will be measured from the time of the Verizon Wireless’ initial call to the Vendor until the time the Vendor’s engineer or technician responds, by telephone or email, to the Verizon
Wireless’ Data NOC or specified incident contact. 
 “Restore or Restoration” means a condition where an item acknowledged
as having a Defect is operative within the specifications, but a permanent resolution has not yet been implemented. Restoration may take the form of a software patch, which has been implemented to temporarily correct the Defect, or a work-around,
which has been mutually agreed upon by the Parties. The Restoration time will be measured from the time of the Verizon Wireless’ initial call to the vendor until Restoration of the applicable defect. 

“Resolve or Resolution” means that a permanent solution to the Defect has been implemented. The Resolution will cause the previously
defective item to operate within the specifications. For service requests, Resolve means that the applicable question has been answered. The Resolution time will be measured from the time of the Verizon Wireless’ initial call to the Vendor
until Resolution of the applicable defect, *** wherein the response time will begin from the point of failure. 
 “Planned Service
Availability” *** 
 “Platform” is the Vendors hardware and software that provide the Verizon Wireless WAP 2.0 portal
services. 
  
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 2 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

 “Service Availability” *** 

“Scheduled Maintenance Time” *** 

“System Outage” *** 

“Technical Support” shall have the meaning set forth in the Vendor’s Responsibilities and Services Section hereto. 

“Transaction” *** 

“Transaction Failure” *** 

“Unscheduled Downtime” *** 

“Vendor” means InfoSpace, Inc or any InfoSpace subsidiaries. 

 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 3 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

	2	Roles and Responsibilities 

  

	2.1	Overview 

 This section defines the roles and
responsibilities of the Vendor and Verizon Wireless of the services described in this SLA. 
 InfoSpace has adopted the RACI Model as a means of
defining, documenting, and communicating roles and responsibilities. The RACI Model describes four (4) roles as described in Table 2 below. 
  

			
	 Role
	  	 Description

	Accountable ( A )	  	Full accountability for the success or failure of a task, project, or program.
	Responsible ( R )	  	Assigned authority, executes defined work, and held responsible for success or failure of assignment(s).
	Consult ( C )	  	Facilitates and contributes as needed (consultant).
	Inform ( I )	  	Potential for contribution, but primary purpose is to maintain a line of communication to outside group.

Table 2 – RACI Model 

With the identification and agreement of services, stakeholders, tasks/activities, the RACI Model provides a means to define a set of roles for each
task/activity. Each task/activity should be assigned a single accountable, however may involve multiple responsible, consulted, and informed participants. 
  

	2.2	Stakeholders 

 *** 

 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 4 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

 *** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 5 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

	3	Service Availability, Service Performance and Response/Restore Times 

 

	3.1	Overview 

 Recognizing the impact to Users as a
result of limited availability and poor performance of the WAP 2.0 system, InfoSpace is committed to supplying reliable service with sufficient capacity designed to provide an enriching and satisfying experience. In order to meet this objective,
InfoSpace will implement appropriate tools and processes intended to support the management of service level targets. This Section describes the metrics, targets, and reports intended to provide the appropriate visibility of availability,
performance and response trends. 
 This section identifies the service levels InfoSpace is expected to consistently achieve throughout the Term
of this Agreement. If and when problems arise that effect service levels, InfoSpace is expected to make every effort to restore service and correct underlying faults. *** 

 

	3.2	Service Availability Metrics 

 Service
availability is measured as described with the following formula: 
 *** 

 

	3.3	Service Performance Metrics 

 Service performance
measures 
 *** 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 6 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

 *** 
  

	4	Credits 

  

	4.1	Service Availability 

 In the event that Service
Availability of the elements or aspects of the Portal and Hosting Service within the InfoSpace Span of Control fails to meet the targeted Service Level Requirements (as listed on Table 4), during any calendar month of the Term, InfoSpace shall make
all reasonable 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 7 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

 efforts to remedy the situation during this “grace period”. If a measure continues to fail to
meet targeted services for a second consecutive month, Verizon Wireless shall receive a credit of a portion of the Monthly Fees otherwise due to InfoSpace during such month for delivery and for all consecutive subsequent months that the target is
missed. This one month “grace period” shall apply only one time during the life of the contract. 
 The credit shall be calculated as
follows: *** 
 *** 
  

	4.2	Service Performance 

 In the event that Service
Performance of the elements or aspects of the Portal and Hosting Service within the InfoSpace Span of Control fails to meet the targeted Service Level Requirements (as listed on Table 5) during any calendar month of the Term, InfoSpace shall make
all reasonable efforts to remedy the situation during this “grace period”. If a measure continues to fail to meet targeted services for a second consecutive month, Verizon Wireless shall receive a credit of a portion of the Monthly Fees
otherwise due to InfoSpace during such month for delivery and for all consecutive subsequent months that the target is missed. This one month “grace period” shall apply only one time during the life of the contract. 

The credit shall be calculated as follows: *** 

In no event shall the cumulative monthly credit exceed *** . 

*** 
 *** 

 

	4.3	*** 

  

	4.4	Cumulative Maximum Monthly Credit 

 ***

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 8 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

 *** 
  

	5	Incident Management 

  

	5.1	InfoSpace Carrier Care 

 InfoSpace’s
Carrier Care within the Network Operations Center (NOC) will serve as the primary interface between Verizon Wireless’ Support Group and InfoSpace for support of services provided by InfoSpace. This arrangement provides Verizon Wireless with
access to a 24x7 single point of contact (SPOC) to report incidents, receive updates, and escalate as needed. Table 9 provides InfoSpace’s Carrier Care hours of operation and contact information. 

 

			
	***	  	 ***

	Contact Phone Number	  	***
	Email Address	  	***

 Table 9 - InfoSpace Carrier
Care Contact Information 
  

	5.1.1	InfoSpace Carrier Care Services 

 The following
list describes Carrier Care services provided to Verizon Wireless: 
  

	 	•	 	 24x7 telephone and email support for incident management. 

 

	 	•	 	 Advisory Bulletins provided on an as needed basis. 

  

	 	•	 	 Notification before and after planned maintenance activities. 

 

	 	•	 	 Post Incident Review Reports (PIRR) for incidents classified as Severity 1 (Sev-1). PIR Reports are delivered within 5 business days of service
restoration. 

  

	5.2	*** 

  

 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 9 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

	5.2.1	*** 

  
  

	5.2.2	Incident Handling and Updates 

 The InfoSpace
Carrier Care will coordinate incident isolation, testing and repair work within InfoSpace and all third party systems that are within InfoSpace’s Span of Control. During the incident isolation and troubleshooting process, InfoSpace’s
Carrier Care will communicate incident resolution progress with Verizon Wireless based upon the times specified in Table 10. Additionally, InfoSpace’s Carrier Care will proactively inform Verizon Wireless when an issue or condition
arises that may cause potential system anomalies and be a potential source for the creation of trouble tickets. 
 *** 

  
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 10 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

 *** 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 11 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

 *** 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 12 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

 *** 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 13 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

 *** 
  

	5.2.3	*** 

 Table 11 – Severity
Level Response Times 
  

	5.2.4	Escalation Procedures 

 InfoSpace Internal
Escalation 
 Escalation procedures are in place at InfoSpace to manage the resolution of incidents when they occur. *** 

Verizon Wireless Escalation to InfoSpace 
 In
the event that InfoSpace does not respond to Verizon Wireless within the times shown in Table 11, Verizon Wireless can request that the incident be escalated to the next level, based on the contact information shared between the two companies
(see Appendix A for an example list of names that are current).*** 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 14 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

 *** 

Table 12 – Escalation Timetable 

*** 
 Additional Escalation Information

 InfoSpace and Verizon Wireless will ensure that any additional processes that are required to ensure the smooth escalation of incidents
within each organization are clearly communicated to one another in writing, so that the escalation processes within each organization and between the two organizations are clearly understood by both parties. InfoSpace and Verizon Wireless will
exchange the names and contact information of the personnel who need to be kept informed of progress during the Escalation process. Both Parties are responsible for ensuring that the contact information is updated and exchanged when circumstances
warrant. 
  

	5.3	Incident Notification Process 

  

	5.3.1	Communicating Incidents 

 To provide the most
expeditious response, InfoSpace requests Verizon Wireless report all incidents to InfoSpace in the following manner: 
 *** 

 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 15 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

 *** 
  

	6	InfoSpace Generated Reports 

  

	6.1	Post Incident Review Reports 

 The purpose of the
Post Incident Review Report (PIRR) is to report the results of InfoSpace’s formal review of an incident, intended to identify root cause, review the teams’ response, and document corrective actions to improve response and prevent
reoccurrence. InfoSpace will create and submit a PIRR to Verizon Wireless within *** 
  

	6.2	Service Level Reporting 

Each month, InfoSpace will provide Verizon Wireless a report summarizing Service Availability, Service Performance, and
Response/Restore times for the previous month.*** 
  

 Page 16 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

 *** 
  

	6.3	Open Issues List Reporting 

Each month, InfoSpace will provide Verizon Wireless with a Reported Incidents Report. *** 

 

	7	Change Management 

 InfoSpace is committed
to supporting formal change and release management process intended to mitigate risk of adversely impacting service delivery to Users. In accord with Verizon Wireless, InfoSpace will participate in the coordination and communication of necessary
maintenance activities, ensuring maintenance is completed at appropriates times, with the appropriate visibility and awareness. 
 ***

  
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 17 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

 *** 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 18 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

 *** 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 19 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

 Appendix A – Support Contact & Escalation List 

Both parties are responsible for ensuring support contact information is maintained and communicated as needed. Support contact
information will not be maintained as part of this SLA. Contact information will be maintained independent of this document by the stakeholders. 

InfoSpace Support Contact Information 
  

			
	Single Point of Contact Name	  	***
		
	Phone	  	***
		
	Email	  	***
		
	Second Level Contact Name	  	***
		
	Title	  	Manager, Service Desk Operations
		
	Phone	  	***
		
	Email	  	***
		
	Third Level Contact Name	  	***
		
	Title	  	Director, Commercial Operations and Internal Support
		
	Phone	  	***
		
	Email	  	***
		
	Fourth Level Contact Name	  	***
		
	Title	  	Director, Carrier Sales
		
	Phone	  	***
		
	Email	  	***
		
	Fifth Level Contact Name	  	***
		
	Title	  	Vice President, Carrier Sales
		
	Phone	  	***
		
	Email	  	***

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 20 

 Verizon Wireless Support Contact Information 

 

			
	Single Point of Contact Name	  	***
		
	Title	  	
		
	Phone	  	***
		
	Email	  	***
		
	Second Level Contact Name	  	***
		
	Title	  	***
		
	Phone	  	***
		
	Phone	  	***
		
	Phone (After Hours)	  	***
		
	Email	  	***
		
	Second Level Contact Name	  	***
		
	Title	  	***
		
	Phone	  	***
		
	Phone	  	***
		
	Phone (After Hours)	  	***
		
	Email	  	***
		
	Third Level Contact Name	  	***
		
	Title	  	***
		
	Phone	  	***
		
	Phone	  	***
		
	Phone (After Hours)	  	***
		
	Email	  	***

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 21 

 Verizon Wireless WAP 2.0 Service Level Agreement 

 

 Appendix B – WAP 2.0 End Device List 

 

							
	 Phones
	 	 PDAs and Handsets

	 Manufacturer
	 	 Model
	 	 Manufacture
	 	 Model

				
	***	 	***	 		 	
				
	***	 	***	 		 	
				
	***	 	***	 		 	
				
	***	 	***	 		 	
				
	***	 	***	 		 	
				
	***	 	***	 		 	
				
	***	 	***	 		 	
				
	***	 	***	 		 	
				
	***	 	***	 		 	
				
		 		 		 	

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 22 

 FIRST AMENDMENT TO WAP 2.0 HOSTING AGREEMENT 

This First Amendment to the WAP 2.0 Hosting Agreement (this “First Amendment”), dated as of August __, 2004 (the
“Amendment Date”), is made by and between Premium Wireless Services USA, Inc., a California corporation and wholly-owned subsidiary of InfoSpace, Inc. (“InfoSpace”), with offices at 10940 Wilshire Blvd.,
9th Floor, Los Angeles, CA 90024, and Cellco Partnership
d/b/a Verizon Wireless (“Verizon Wireless”), a Delaware general partnership, having an office and principal place of business at 180 Washington Valley Road, Bedminster, New Jersey 07921, to amend that certain WAP 2.0 Hosting
Agreement executed by and between the Parties on or about June 24, 2004 (the “Agreement”). InfoSpace and Verizon Wireless are sometimes individually referred to herein as a “Party” and may be collectively
referred to as the “Parties.” Unless specifically designated otherwise, the capitalized terms herein shall have the same meanings given them in the Agreement and any Amendment. 

RECITALS 
 A. WHEREAS,
InfoSpace and Verizon Wireless desire to incorporate terms related to certain content hosting services provided by InfoSpace to Verizon Wireless in connection with the provision of Portal Services pursuant to and in accordance with the terms and
conditions set forth in the Agreement. 
 B. WHEREAS, Verizon Wireless and InfoSpace have agreed to amend the Agreement as per the terms and
conditions set forth below. 
 C. NOW, THEREFORE, in consideration of the foregoing, the mutual covenants contained herein, and for other good
and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, Parties hereto agree as follows: 

AGREEMENT 

1. Amendment to Section 15.14.1.c. (Insurance). 

The Parties agree that the words “and patent” shall be deleted from Section 15.14.1.c., and that the word “or”
shall be inserted between the words “copyright” and “trademark.” 
 2. Content Hosting Services. A new
section is hereby added to the Agreement, Section 16, as follows: 
 16 Content Hosting Services. 

16.1 Description of Content Hosting Services. 

16.1.1 Subject to the terms and conditions of this Agreement and the satisfaction of Verizon Wireless’ obligations set forth
in Section 16.1.2 below, InfoSpace will exercise commercially reasonable efforts to develop, test and publish within *** of this Amendment Date or as otherwise agreed to by Verizon Wireless, the following applications *** to the dedicated
hosting environment: 
 16.1.1.1 General News (as provided ***); 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

 16.1.1.2 Weather (as provided ***); 

16.1.1.3 Sports (as provided ***); 

16.1.1.4 Sports News (as provided ***); 

16.1.1.5 Market News (as provided ***); 

16.1.1.6 Finance (as provided ***). 

Attached to this Agreement as Exhibit Q, are the content hosting service descriptions. 

16.1.2 Verizon Wireless will perform the following tasks with respect to the above applications: 

16.1.2.1 Obtain the applicable content (the “Hosted Content”) from third-party content providers for each of the
applications set forth in Section 16.1.1 above, and 
 16.1.2.2 Obtain all necessary rights, privileges, permission, and
authority necessary for InfoSpace to host and distribute the Hosted Content as contemplated by this Agreement. 
 16.2
Content Services Set Up Fee. ***, Verizon Wireless will pay InfoSpace a one-time fee of *** (the “Content Services Set Up Fee”) for the Configuration Services (as defined below) and the Integration Services (as defined below)
provided by InfoSpace to Verizon Wireless. 
 16.2.1 For the purposes of this Agreement, “Configuration
Services” means the configuration of a pre-production and production hosting environment, including all required hardware, software, monitoring/alarm systems, 24-7-365 support processes, network infrastructure components, firewalls, release
management process, phase I of the content entry tool and feed viewing process for Vindigo, and the content management system. 

16.2.2 For the purposes of this Section, “Integration Services” means, with respect to each content feed, the
following: 
 16.2.2.1 the creation of technical specifications and/or application based on InfoSpace and Vindigo designs;

 16.2.2.2 the integration of backend feeds as appropriate; 

16.2.2.3 the creation of application logic for each content application; 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 2 

 16.2.2.4 the creation of the WAP user interface template; 

16.2.2.5 the creation and execution of test plans to ensure application functionality; 

16.2.2.6 support of a User Acceptance testing period and Revenue Assurance testing period; 

16.2.2.7 publishing of code to each success environment including production; and 

16.2.2.8 adherence to SLA targets. 

16.3 Content Hosting. InfoSpace will provide the following hosting services with respect to content feeds in the production
environment (regardless of whether the content is sourced by InfoSpace or Verizon Wireless): 
 16.3.1 content feed monitoring
for timeliness and quality; 
 16.3.2 resources and systems to manage content providers and content feeds listed in section
16.1.1; 
 16.3.3 feed integration maintenance to ensure that databases and APIs function within acceptable parameters;

 16.3.4 hardware, software, and network scaling as volume ramps up; 

16.3.5 rendering of WAP and web pages for the applications listed in section 16.1.1; 

16.3.6 resources and systems to manage content feeds and the application hosting environment; 

16.3.7 24-7-365 production support; 

16.3.8 content usage reporting; and 

16.3.9 performance monitoring and reporting. 

16.4 Fees. In addition to the fees set forth in Exhibit D (Section I.3.) of the Agreement, Verizon Wireless shall pay to InfoSpace
a Premium Page View Fee (as defined below) for each Content Page View hosted by InfoSpace. 
  

16.5 *** 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 3 

 16.6 Ownership. Subject to Section 2.10 and Section 12 of this
Agreement, Verizon Wireless shall own the source code to the above listed applications; provided, however, InfoSpace will retain all right, title and interest to all of its pre-existing Intellectual Property, including but not limited
to designs, tools, source code, object code, software, applications, modules and interfaces. 
 16.7 Page view reports,
detailing all Page Views, must be delivered within 15 days of the end of the month for which the reporting is being made. 

3. Minimum Page View Fee. The definition of “Minimum Page View Fee” set forth in Paragraph 3 of Exhibit D (Section I.3.)
of the Agreement is hereby amended and replaced in its entirety by the following: 
 Minimum Page View Fee means, for any
calendar month during the Term of the Agreement, a sum in the amount of *** This applies to the sum of the Page View Fee and the Premium Page View Fee. 

4. Third-Party Contact Information. Within ten (10) days of the later of the Amendment Date or the execution of a
contract between Verizon Wireless and a third-party for the purposes of providing content under the Agreement or this Amendment (the “Third-Party Content Provider”), Verizon Wireless agrees to provide to InfoSpace the contact
information of each Third-Party Content Provider, consisting of the company name, an individual contact name, and the applicable address, phone number, and facsimile number. 

5. IT SLA. The Parties agree that the Agreement shall be amended to include an IT SLA which shall be attached to the
Agreement as Exhibit H-2 
 6. Existing Provisions. For emphasis, the Parties agree that, except as amended herein, all
provisions of the Agreement, including, but not limited to the following Sections, shall apply to all terms of this Amendment: 
  

	 	a.	Warranties (Sections 11.1 through 11.3), 

  

	 	b.	Disclaimer (Section 11.4), 

  

	 	c.	Indemnification (Section 11.5), and 

  

	 	d.	Limitation of Liability (Section 11.6). 

7. Confidentiality. The Parties agree that the definition of “Confidential Information” in Exhibit A, Section 7,
shall be amended, for clarification purposes only and for the avoidance of doubt, to include the term “Wireless Devices.” More specifically, “Wireless Devices” shall be inserted between the words “samples” and
“reports.” 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 4 

 8. Security. The Parties agree that, for clarification purposes only and for the
avoidance of doubt, a new Section shall be added to the Agreement, Section 17. Section 17 shall state the following: 

The Parties agree that each is responsible for the actions and omissions of its respective officers, employees, contractors,
representatives and agents (for the purposes of this Section only “Representatives”). Each Party agrees to promptly notify the other Party in the event it discovers that one of its Representatives has violated any provision of this
Agreement, or that any such Representative has violated any law, rule or regulation. 
 The Parties agree to cooperate with each
other to remedy any act or omission caused by one of their Representatives. This shall include, but not be limited to the exchange of information relative to any such act or omission, ***. 

*** 
 Except as specifically
amended herein, the Agreement, including any amendments, shall remain in full force and effect. 
 This Amendment may be executed in
counterparts, each of which shall constitute an original and all of which together shall constitute one instrument. 
 If there are any
inconsistencies between a provision of this Amendment and a provision of the Agreement, the provision of this Amendment shall control, however, only with regard to the subject of the inconsistency. 

The Parties have executed this Amendment as of the day and year written above. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 5 

					
	Cellco Partnership d/b/a Verizon Wireless	 		 	Premium Wireless Services USA, Inc.
			
	/s/ ***	 		 	/s/ M. Dean Newton
	By (signature)	 		 	By (signature)
			
	***	 		 	M. Dean Newton
	Name	 		 	Name
			
	VP - Tech Dev.	 		 	VP Entertainment Media & Business Affairs InfoSpace Mobile
	Title	 		 	Title
			
		 		 	InfoSpace, Inc.
			
	 	 		 	/s/ M. Dean Newton
		 		 	By (signature)
			
	 	 		 	M. Dean Newton
		 		 	Name
			
	 	 		 	VP Entertainment Media & Business Affairs InfoSpace Mobile
		 		 	Title

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 Page 6 

 AMENDMENT NUMBER 2 

TO 

AGREEMENT NUMBER 750-67761-2004 

BETWEEN 

CELLCO PARTNERSHIP d/b/a VERIZON WIRELESS 

AND 

INFOSPACE MOBILE, INC. 

f/k/a PREMIUM WIRELESS SERVICES USA, INC. 

A WHOLLY OWNED SUBSIDIARY OF INFOSPACE, INC. 
  

	1.	PARTIES. 

This Amendment Number 2 (“Second Amendment”) to the WAP 2.0 Hosting Agreement dated June 24, 2004, as amended by the First
Amendment to WAP 2.0 Hosting Agreement, dated August 31, 2004 (as amended, the “Agreement”), by and between InfoSpace Mobile, Inc. f/k/a Premium Wireless Services USA, Inc., a California corporation and wholly owned subsidiary of
InfoSpace, Inc., with offices at 10960 Wilshire Blvd., Suite 800, Los Angeles, CA 90024 (“InfoSpace”) and Cellco Partnership d/b/a Verizon Wireless, a Delaware general partnership, having an office and principal place of business at One
Verizon Way, Basking Ridge, NJ 07920 (“Verizon Wireless”), is made and entered into on and as of the date of execution by the last signing Party (the “Second Amendment Effective Date”). 

 

	2.	AMENDMENT OF AGREEMENT. 

  

	A.	Section 2.1 of the Agreement shall be amended by deleting it in its entirety and replacing it with the following: 

 

	 	2.1.	InfoSpace Services. 

  

	 	a.	Subject to the terms and conditions of this Agreement, during the Term, InfoSpace will make available to Verizon Wireless the Portal Services described in Exhibit B.

  

	 	b.	In addition, InfoSpace shall furnish Portal Services as set forth in Work Orders in the form set forth in Exhibit E to this Agreement issued from time to time by
Verizon Wireless and accepted by Infospace, in accordance with Section 2.11 of the Agreement. 

  

	 	c.	Subject to the terms and conditions of the Agreement and this Second Amendment, during the Term, InfoSpace will make available to Verizon Wireless the services
described in the Work Order attached hereto as Exhibit A to this Second Amendment (the “FlashCast Services”). The FlashCast Services shall constitute Portal Services under the Agreement. 

 

 1 

	 	d.	Unless otherwise expressly set forth in a Work Order, Verizon Wireless may terminate Portal Services for convenience, in whole or in part, without obligation or
liability for future monthly support fees, by providing written notice to Infospace *** before the Portal Services are made commercially available. In the event of such termination, Verizon Wireless shall pay InfoSpace all outstanding fees due and
payable under the applicable Work Order through the date of termination. InfoSpace shall invoice Verizon Wireless for such fees and Verizon Wireless shall remit payment to InfoSpace in accordance with the Agreement. If the charges for such
terminated Portal Services were paid in advance, Infospace shall promptly refund to Verizon Wireless those fees paid for services not rendered prior to the date of termination. For the avoidance of doubt, in the event of termination by Verizon
Wireless of the FlashCast Services, in whole or in part, as set forth in this Section 2.1(d), InfoSpace shall be entitled to retain *** set forth in Attachment 3 to Exhibit A. 

 

	B.	Section 2.7 and Section 2.10 of the Agreement shall be amended by inserting the following at the beginning of such Sections: 

“With respect to the Portal Services set forth in Exhibit B to this Agreement” 

 

	C.	Section 5.1 shall be amended by inserting the words “set forth in Exhibit B” after the words “Portal Services”. 

 

	D.	Section 5.3(c) of the Agreement shall be amended by inserting the words “or FlashCast Wireless Devices” after the reference to “Wireless
Devices”. 

  

	E.	Section 8.1 of the Agreement shall be amended by deleting it in its entirety and replacing it with the following: 

 

	 	8.1	Term. The term of this Agreement shall commence on the Effective Date and unless earlier terminated pursuant to the terms of this Agreement, shall end
March 1, 2010 (the “Term”), provided that the Term shall be automatically renewed for successive one (1) year periods unless either Party provides written notice of termination to the other Party at least ninety (90) days
prior to the end of the then-current Term. 

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 2 

	F.	Section 8.2 of the Agreement shall be amended by adding: 

  

	 	d.	For Convenience. Verizon Wireless may terminate Portal Services for convenience, in whole or in part, without obligation or liability for future monthly support fees by
providing Infospace with *** prior written notice. 

  

	 	e.	For Uncured Security Vulnerability. Verizon Wireless may terminate this Agreement in accordance with Section 5.3(b)(iii) of this Agreement.

  

	G.	Section 9 of the Agreement shall be amended by 

  

	 	1.	inserting the following at the beginning of such Section: 

“This Section 9 applies solely to the Portal Services set forth in Exhibit B to this Agreement. Transition Services to be
provided in connection with any Portal Services provided pursuant to a Work Order, shall be set forth in such Work Order.” ; and 
  

	 	2.	deleting subsection 9.1(b) and replacing it with the following: 

The Parties agree that (a) during the Transition Period, additional Users shall be permitted to subscribe to the Portal Services and
(b) following the Transition Period no additional User shall be permitted to subscribe to the Portal Services. 
  

	H.	With respect to Section 10.2, the Parties acknowledge and agree that separate Steering Committees, with different members from each Party, may be formed for each
Project set forth in a Work Order or an amendment to this Agreement. 

  

	I.	Section 11.2(e). of the Agreement shall be amended by deleting it in its entirety and replacing it with the following: 

11.2(e). InfoSpace represents and warrants that (i) the Portal Services set forth in Exhibit B shall operate in
substantial conformity with the specifications contained in Exhibit J and (ii) additional Portal Services shall operate as set forth in the applicable Work Order. 
  

	J.	 Section 11.6 of the Agreement shall be modified to clarify its original intent by inserting a period in the eleventh
(11th) line down after the words “Section
11” and ***. In addition, the penultimate sentence of Section 11.6 shall be amended by inserting the following after subsection (v): 

*** 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 3 

	K.	Section 12.2 shall be amended to clarify its original intent by changing the reference to “Section 11.1” to “Section 12.1”.

  

	L.	Section 12.12 of the Agreement shall be amended by deleting it in its entirety and replacing it with the following: 

Section 12.12 Developed Technology. The Parties contemplate that, from time-to-time, one Party may agree to develop Developed
Technology for the other Party pursuant to a Work Order or an amendment to this Agreement. The ownership and/or license right in such Developed Technology, compensation for its development and other terms regarding Developed Technology shall be as
set forth in such Work Order or amendment. 
  

	M.	Section 15.1.a. of the Agreement shall be amended by inserting the following at the beginning of such Section: 

“With respect to the Portal Services set forth in Exhibit B to this Agreement” 

 

	N.	Section 15.5 of the Agreement shall be amended by inserting the following at the end of such Section: 

“The application of the UN Convention on Contracts for the International Sale of Goods is specifically excluded from this Agreement.
Furthermore, in no event shall this Agreement become subject to the Uniform Computer Information Transactions Act (UCITA) even if passed by the state of governing law.” 

 

	O.	Section 15.6(a) shall be amended by deleting it in its entirety and replacing it with the following: 

In addition, any controversy or claim arising out of or relating to this Agreement, or the breach, termination or validity thereof, may,
if the parties so elect, be settled by a sole arbitrator in accordance with the CPR Non-Administered Arbitration Rules. The arbitration shall be governed by the United States Arbitration Act, 9 U.S.C. §§ 1-16, and judgment upon the award
rendered by the Arbitrators may be entered by any court having jurisdiction thereof. The place of the arbitration shall be New York, New York. Punitive and exemplary damages shall not be awarded. Process

  

 4 

 
may be served on either party by U.S. Mail, postage prepaid, certified or registered, return receipt requested, or by such other method as is authorized by law. Notwithstanding the foregoing,
each Party may institute formal proceedings at any time with a court of competent jurisdiction to avoid the expiration of any applicable limitations period, to preserve a superior position with respect to other creditors, or as provided in 15.6(b)
(“Injunctive Relief”) below. 
  

	P.	Section 15.9 of the Agreement shall be modified to update the Notice contacts as follows: 

To Verizon Wireless: 

Verizon Wireless 

One Verizon Way 

Basking Ridge, NJ 07920 

Attn: *** Executive Vice President and Chief Technical Officer 

Copies to: 

Assistant General Counsel – Sourcing 

One Verizon Way, VC33E270 

Basking Ridge, NJ 07920 

To InfoSpace: 

InfoSpace Mobile, Inc. 

10960 Wilshire Blvd., Suite 800 

Los Angeles, CA 90024 

Fax: (310) 481-6838 

Attention: President, Mobile and Online Media 

With a copy to: 

InfoSpace Mobile, Inc. 

601
108th Ave. NE 

Suite 1200 

Bellevue, WA 98004 

Attention: Senior Corporate Counsel, 

Entertainment Media & Business Affairs 

Fax: (425) 201-6110 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 5 

	Q.	The Agreement shall be amended by deleting Exhibit D to the Agreement and replacing it with the pricing set forth in the revised Exhibit D attached to this Second
Amendment with respect to the Portal Services set forth in Exhibit B. 

  

	R.	The Agreement shall be amended such that all references to Exhibit D in the Agreement shall be deemed references to Exhibit D with respect to the Portal Services set
forth in Exhibit B, and with respect to Portal Services other than those set forth in Exhibit B, references to Exhibit D in the Agreement shall be deemed to be references to the commercial terms set forth in the applicable Work Order.

  

	S.	Section 6 of Exhibit A of the Agreement shall be amended by deleting it in its entirety and replacing it with the following: 

6. “Commercial Service Date” means, with respect to the Portal Services set forth in Exhibit B, the earlier of
(a) June, 25, 2004, or (b) the date of Verizon Wireless’ written acceptance of the Portal Services in accordance with Section 1(b) of Exhibit D. 
  

	T.	Section 27 of Exhibit A of the Agreement shall be amended by deleting it in its entirety and replacing it with the following: 

27. “Portal Services” means the products and services that will be made available to Verizon Wireless by InfoSpace as set
forth in this Agreement, and pursuant to (i) the specifications of Exhibit B or (ii) the specifications set forth in the applicable Work Order or written amendment entered into by the Parties. 

 

	U.	Exhibit H-1 to the Agreement shall be amended as set forth in the revised Exhibit H-1 attached to this Second Amendment. 

 

	V.	Exhibit H-2 to the Agreement shall be amended as set forth in the revised Exhibit H-2 attached to this Second Amendment. 

 

	W.	The Agreement shall be amended by adding a new Exhibit S, in the form attached hereto as Exhibit S. 

 

	X.	The Parties acknowledge and agree that (i) Exhibits D, F, G, H-1, H-2, I, J, L, N, O, P and Q apply only to the Portal Services set forth in Exhibit B, and
Amendment 1 and Exhibits A, C, E, K, and S apply to any Portal Services. 

  

	Y.	InfoSpace shall provide the services set forth in the Work Order attached as Exhibit A to this Second Amendment as set forth therein. 

 

 6 

	Z.	The Parties agree to issue, promptly upon the execution of this Second Amendment, a joint press release announcing the extension of the Mobile Web 2.0 Services,
provided that neither Party shall issue any such press release without the prior written consent of the other Party. 

  

	3.	EFFECT OF AMENDMENT. 

This Second Amendment is an integral part of the Agreement. Terms used herein which are defined or specified in the Agreement shall have
the meanings set forth therein. If there are any inconsistencies between a specific term or condition of this Second Amendment and a specific term or condition of the Agreement, the specific term or condition of this Second Amendment shall control,
but only to the extent of such inconsistencies. 
 Except as amended hereby, the Agreement shall continue in full force and
effect. 
  

	4.	SIGNATURES. 

 IN
WITNESS WHEREOF, the Parties hereto have caused this Second Amendment to be executed by their duly authorized officers or representatives. 
  

 7 

									
	CELLCO PARTNERSHIP d/b/a	 		 	
	Verizon Wireless	 		 	INFOSPACE MOBILE, INC.
					
	By:	 	 	 		 	By:	 	***
	Name:	 	 	 		 	Name:	 	***
	Title:	 	 	 		 	Title:	 	Chr./CEO
	Date:	 	 	 		 	Date:	 	4/4/07
			
		 		 	INFOSPACE, INC.
		 		 	Solely for the purpose of Section 15.20 hereunder
					
		 		 		 	By:	 	***
		 		 		 	Name:	 	***
		 		 		 	Title:	 	Chr./CEO
		 		 		 	Date:	 	4/4/07

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 8 

 revised Exhibit D 

Amendments to Exhibit D of WAP 2.0 Hosting Agreement 

Exhibit D of the Agreement shall hereby be amended as follows: 

*** 
  
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 9 

 ***
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 10 

 *** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 11 

 revised Exhibit H-1 

Amendments to Verizon Wireless 

WAP 2.0 Portal Services Service Level Agreement 

The Verizon Wireless WAP 2.0 Portal Services Service Level Agreement (Exhibit H-1 to the Agreement) shall hereby be amended as follows: 

 

	1.	Section 4 shall be deleted in its entirety and replaced with the following: 

 

	4	Credits 

  

	4.1	Service Availability 

 In the event that Service
Availability of the Service Components of the Portal Services within the InfoSpace Span of Control set forth in Table 4 fails to meet the Availability Target (as listed in Table 4), during any calendar month of the Term, InfoSpace shall make all
reasonable efforts to remedy the situation during this “grace period”. If a measure continues to fail to meet targeted services for a second consecutive month, Verizon Wireless shall receive a credit of a portion of the Mobile Web 2.0 Fee
otherwise due to InfoSpace during such month for delivery and for all consecutive subsequent months that the target is missed. This one month “grace period” shall apply only one time during the life of the contract. 

The credit shall be calculated as follows: *** (as shown on Table 7 below). 

*** 
 Table 7 – Credit
Structure Service Availability 
  

			
	***	  	

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 12 

 *** 
  

	4.2	Service Performance 

 In the event that
Service Performance of the Service Components of the Portal Services within the InfoSpace Span of Control set forth in Table 5 fails to meet the Performance Targets (as listed on Table 5) during any calendar month of the Term, InfoSpace shall make
all reasonable efforts to remedy the situation during this “grace period”. If a measure continues to fail to meet targeted services for a second consecutive month, Verizon Wireless shall receive a credit of a portion of the Mobile Web 2.0
Fee otherwise due to InfoSpace during such month for delivery and for all consecutive subsequent months that the target is missed. This one month “grace period” shall apply only one time during the life of the contract. 

The credit shall be calculated as follows: *** 
  

 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 13 

 *** 

Table 8 – Credit Structure Service Performance 

 

							
	***	  		  		  	

  
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 14 

	4.3	*** 

  

	4.4	*** 

  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 15 

 *** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 16 

 *** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 17 

 *** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 18 

 *** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 19 

 *** 
  

	2.	Table 11 shall be deleted in its entirety and replaced with the following: 

*** 
  

							
	 Severity Level
	  	 Response Time
	  	 Restore Time
	    	 Resolve time-Permanent Fix

	 Severity 1
	  	 ***
 into InfoSpace’s
Carrier Care
	  	***	    	 ***

				
	 Severity Level
	  	 Response Time
	  	 Restore Time
	    	 Resolve time-Permanent Fix

	 Severity 2
	  	 ***
 into InfoSpace’s
Carrier Care
	  	***	    	 ***

				
	 Severity Level
	  	 Response Time
	  	 Restore Time
	    	 Resolve time-Permanent Fix

	 Severity 3
	  	 *** of
 Verizon
Wireless’ e-mail or phone notification
	  	***	    	 ***

				
	 Severity Level
	  	 Response Time
	  	 Restore Time
	    	 Resolve time-Permanent Fix

	 Severity 4
	  	 ***
 Verizon Wireless’
e-mail or phone notification
	  	***	    	 ***

Table 11 – Severity Level Response Times 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 20 

 Revised Exhibit H-2 

Amendment to Exhibit H-2 (WAP 2.0 IT Interface Service Level Agreement) 

The Verizon Wireless WAP 2.0 IT Interface Service Level Agreement (Exhibit H-2 to the Agreement) shall hereby be amended as follows: 

 

	1.	Section 4 shall be deleted in its entirety and replaced with the following: 

 

	4.	Credits 

 System Availability Credits

 *** 
  

 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 21 

 *** 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 22 

 *** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 23 

 *** 
  

			
	First Level Contact Name	  	Carrier Care
	Phone	  	1-425-201-8700
	Email	  	***
		
	Second Level Contact Name	  	***
	Title	  	Service Operations Manager
	Phone	  	***
	Email	  	***
		
	Third Level Contact Name	  	***
	Title	  	Director, Commercial Operations
	Phone	  	***
	Email	  	***
		
	Fourth Level Contact Name	  	***
	Title	  	VP IT Operations
	Phone	  	***
	Email	  	***

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 24 

 EXHIBIT S 

SECURITY REQUIREMENTS 

*** 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 25 

 EXHIBIT A TO SECOND AMENDMENT TO 

AGREEMENT NO. 750-67761-2004 BETWEEN VERIZON WIRELESS AND 

INFOSPACE 
 WORK
ORDER 
 for 

FLASHCAST SERVICES 
  

	1.	DEFINITIONS. 

 In addition to the terms set forth
in the Agreement, the terms defined in this Section 1 shall have the meanings set forth below whenever they appear in this Work Order unless the context in which they are used clearly requires a different meaning or a different definition is
described for a particular Section or provision: 
  

	1.1	“Active User” means any User who (a) has a FlashCast Wireless Device, and (b) has successfully registered with Verizon Wireless and remains
authorized by Verizon Wireless to use the Verizon Wireless FlashCast Service and (c) is receiving updates to one or more Channels. Verizon Wireless business records shall be conclusive in determining whether a User is an Active User. For
greater certainty, the term “Active User” includes any User who subscribes to Verizon Wireless Services and registers to use the Verizon Wireless FlashCast Service, either directly with Verizon Wireless or indirectly through an Indirect
Channel Entity. 

  

	1.2	“Background Materials” means InfoSpace’s tangible and intangible materials and intellectual property, including without limitation the InfoSpace platform
and messaging gateway, reports, documentation, drawings, computer programs (source code, object code and listings), inventions, know-how, creations, works, devices, masks, models and work-in-process, and any improvements, enhancements or
modifications thereto, that InfoSpace uses to develop and/or provide the FlashCast Services. 

  

	1.3	“Channel” means a single grouping of distinct information, displayed on a FlashCast Wireless Device, that (i) can be independently downloaded or added by
the Active User, or (ii) can independently receive periodic updates, or (iii) can be controlled and configured by the Active User independently from other Channels. 

 

	1.4	“Documentation” means the documentation listed on Schedule 4 and all amendments and updates thereto issued by InfoSpace. 

 

	1.5	“FlashCast Content” means digital media objects that (i) are owned by Verizon Wireless or licensed to Verizon Wireless by third parties and that
(ii) Active Users may preview, download, display, store or otherwise use via the Verizon Wireless FlashCast Service. For greater certainty, FlashCast Content may include audio, pictures, images, text, graphics, video or other media objects.

  

	1.6	“FlashCast Content Provider” means any third party who has licensed FlashCast Content to Verizon Wireless. 

 

 26 

	1.7	“FlashCast Deliverables” means all Documentation and other materials and work product, and all updates thereto, that InfoSpace provides or agrees to provide
to Verizon Wireless in performing the FlashCast Services under this Work Order. 

  

	1.8	“FlashCast Launch Date” means the first date that Verizon Wireless makes the Verizon Wireless FlashCast Service commercially available to its Users. Verizon
Wireless shall have the right to determine the FlashCast Launch Date in its sole discretion, provided however, that the FlashCast Launch Date shall be no earlier than the Effective Date and no later than 12/31/07. 

 

	1.9	“FlashCast Service Level Agreement” or “FlashCast SLA” means the service level agreement setting forth the respective responsibilities of the
Parties regarding support of the FlashCast Services, attached hereto as Attachment 2 and made a part hereof. 

  

	1.10	“FlashCast Statement of Work” or “FlashCast SOW” means the document attached to this Work Order as Attachment 1 (“Statement of Work”) that
describes the FlashCast Services and FlashCast Deliverables that InfoSpace will provide, Verizon Wireless deliverables and related obligations, milestones for implementation, delivery schedules, payment schedules, additional terms and conditions,
and other matters establishing the requirements applicable to the initial project hereunder. 

  

	1.11	“FlashCast Wireless Device” for purposes of this Work Order, means the wireless handset devices that Verizon Wireless has approved for use on the Verizon
Wireless Network and which has had the Flashcast application submitted to NSTL for certification to enable Active Users to access and use the Verizon Wireless FlashCast Service. Such devices are set forth on Schedule 3 to this Second Amendment. The
Parties may amend Schedule 3 from time to time upon written agreement. 

  

	1.12	“Hardware” means the hardware set forth on Schedule 1 and Schedule 2 to this Work Order, as such may be modified from time to time by the parties.

  

	1.13	“Indirect Channel Entity” means an Affiliate, agent, distributor, reseller, MVNO or other Person whom Verizon Wireless has authorized in writing to offer,
promote, market and resell the Verizon Wireless FlashCast Service indirectly or through one or more tiers of indirect distribution, under the Verizon Wireless Marks or the Trademarks of such Indirect Channel Entity. 

 

	1.14	“Premium Channel Content” means FlashCast Content obtained by Active Users from one or more Channels for which Active Users pay fees in addition to standard
subscription fees, which Verizon Wireless may determine in its sole discretion. 

  

	1.15	“Software” means the software set forth on Schedule 1 and Schedule 2 to this Work Order, as such may be modified from time to time by the parties.

  

	1.16	“System” means all Hardware and Software and used by InfoSpace to make available to Verizon Wireless the FlashCast Services as provided in the FlashCast SOW.

  

 27 

	1.17	“Verizon Wireless FlashCast Service” means an on-line digital media service to be offered by Verizon Wireless that will incorporate the FlashCast Services to
be provided by InfoSpace hereunder that will enable Active Users to obtain FlashCast updates. 1.19 “Web Site” means any point of presence maintained on the Internet or on any other public data network accessed via a computing device. With
respect to any Web Site maintained on the World Wide Web, such Web Site includes all HTML Pages (or similar relevant data protocol) that are either identified by the same second-level domain (such as www.verizonwireless.com) or by an equivalent
level identifier in any relevant address scheme. 

  

	2.	SCOPE. 

  

	2.1	Verizon Wireless desires to market and sell a new service offering (the Handset Portal Service a/k/a Verizon Wireless Flashcast Service), that will enable customers who
have a FlashCast Wireless Device to select, preview, purchase and view digital media content updates to a FlashCast Wireless Device. InfoSpace has expertise in implementing, hosting and providing digital media content services, and as such provides
the services and has the capability necessary to host a system that will enable Verizon Wireless to provide this new service offering to its subscribers. Accordingly, InfoSpace shall implement and operate the System, and provide the FlashCast
Services in accordance with the FlashCast Statement of Work. 

  

	2.2	Subject to the terms of this Work Order and the Agreement, InfoSpace hereby grants to Verizon Wireless a worldwide right and license to access and use the FlashCast
Services provided by InfoSpace to offer, market, promote, sell, operate, provide, enhance, support and maintain the Verizon Wireless FlashCast Service, in any manner and on any terms (provided such manner and terms are not in breach of Verizon
Wireless’ representations or obligations under this Work Order and the Agreement), and at any prices as determined by Verizon Wireless from time to time in its sole discretion. Verizon Wireless may exercise such rights directly and through one
or more Indirect Channel Entities, at the same time and from time to time as Verizon Wireless may determine in its sole discretion, subject to Verizon Wireless’ representations and obligations under this Work Order and the Agreement and
provided that as between Verizon Wireless and Infospace, Verizon Wireless shall be responsible, and remain liable to InfoSpace, for any such exercise of rights authorized by Verizon Wireless through any Indirect Channel Entity and further provided
that default by one Indirect Channel Entity shall no affect Verizon Wireless or any other Affiliate party to this Agreement. 2.3 InfoSpace shall provide, perform, and deliver, to the extent set forth herein, the FlashCast Services described in this
Exhibit A. InfoSpace acknowledges and agrees that: 

  

	 	2.3.1	The FlashCast Services are important to Verizon Wireless and InfoSpace must deliver the FlashCast Services in compliance with the FlashCast Statement of Work;

  

 28 

	 	2.3.2	InfoSpace has and must maintain an organization staffed by qualified personnel, including key personnel with the knowledge, skill and resources to perform and complete
the FlashCast Services; 

  

	 	2.3.3	To InfoSpace’s knowledge, there are no impediments or commitments, legal, contractual or otherwise that impede InfoSpace’s timely performance and completion
of the FlashCast Services or its capacity or capability to do so; 

  

	2.4	InfoSpace will provide Verizon Wireless personnel with the training described on Attachment 6. 

 

	3.	PORTAL SERVICE REQUIREMENTS 

  

	3.1	Facility Requirements.  

  

	 	3.1.1	InfoSpace shall install, configure, maintain and support the System, and provide the FlashCast Services as described in this Section 3 and in compliance with
Attachment 1 and in compliance with Attachment 2. 

  

	 	3.1.2	Verizon Wireless acknowledges that Schedule 1 and Schedule 2 set forth the hardware and software necessary to support the capacity requirements for the FlashCast
Services desired by Verizon Wireless and as described in the Statement of Work. To the extent Verizon Wireless desires to increase or decrease the capacity requirements as detailed in Attachment 3, Pricing, of the FlashCast Services, the Parties
shall mutually agree in writing upon any corresponding modifications to the System, including (without limitation) the addition of Hardware or Software. All Hardware and Software purchased by Verizon Wireless set forth on Schedule 1 shall be owned
by Verizon Wireless. Verizon Wireless shall obtain all necessary rights (including any necessary sublicense rights) for InfoSpace to use the Hardware and Software set forth on Schedule 1 as contemplated by this Work Order. All Hardware purchased by
InfoSpace set forth on Schedule 2 shall be owned by Verizon Wireless. Unless otherwise agreed, upon termination or expiration of this Agreement, all Hardware shall be delivered to Verizon Wireless or its designee, and Verizon Wireless shall cover
all actual costs associated with such delivery, including but not limited to, personnel, packing, shipping, insurance and delivery costs. To the extent InfoSpace licenses any Software set forth on Schedule 2 directly from licensors thereof,
InfoSpace shall use commercially reasonable efforts to transfer such licenses upon termination or expiration of this Work Order or in the event Verizon Wireless elects to transfer the support of the Verizon FlashCast Service to Verizon
Wireless’ facilities as set forth in Section 3.1.4. To the extent Verizon Wireless has obtained authorization(s) for InfoSpace to directly provide support and maintenance with respect to any Hardware and Software set forth on Schedule 1,
Infospace shall work directly with the providers of such Hardware and Software to resolve support and maintenance issues which may arise. 

  

 29 

	 	3.1.3	InfoSpace shall provide Verizon Wireless with current mutually agreed performance and monitoring data for the preceding three calendar months within *** of the end of
each calendar month. In addition, upon *** written notice, InfoSpace shall provide Verizon Wireless with physical access to the facilities and systems used by InfoSpace and its subcontractors to provide the FlashCast Services.

  

			
	 3.1.4
	  	(a) InfoSpace shall provide the FlashCast Services to Verizon Wireless during the Term of this Agreement; provided, however, that, subject to 3.1.4(b) below, at any time upon ***
prior written notice to InfoSpace, Verizon Wireless may elect to provide and operate the Verizon Wireless FlashCast Service internally through its own equipment and facilities or through the equipment and facilities of a Third Party. In such event,
subject to Section 3.1.4(b) below, Infospace will continue to provide the FlashCast Services for a specific period of time to be agreed by the Parties in writing not to exceed *** (the “FlashCast Transition Period”), and at Verizon
Wireless’ request, shall transfer to Verizon Wireless all aspects of the System owned by Verizon Wireless, including Hardware and Software licenses, to the extent the Software licenses are transferable to Verizon Wireless. In addition, during
the FlashCast Transition Period and subject to Section 3.1.4(b) below, InfoSpace shall work with Verizon Wireless to provide support, training and assistance Verizon Wireless deems necessary to establish the capability for Verizon Wireless to
provide the Verizon Wireless FlashCast Service without the continued involvement of InfoSpace.

  

	 	    	(b) ***. In the event that Verizon Wireless requests transition services as described in Section 3.1.4(a) above, InfoSpace and Verizon Wireless shall agree to a
statement of work and associated fees prior to the commencement of the FlashCast Transition Period. 

  

	 	    	(c) During the FlashCast Transition Period, the obligations of the Parties as set forth in the Agreement, including but not limited to this Second Amendment, shall
survive. 

  

	3.2	Performance Requirements  

  

	 	3.2.1	InfoSpace shall configure Hardware, Software and connection capacity and services for the FlashCast Services described in Attachment 1. 

 

	 	3.2.2	Each Party shall fully comply with the terms and conditions of the Agreement, the Second Amendment and this Work Order, including all Exhibits and attachments.

  
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 30 

	 	3.2.3	As of the FlashCast Launch Date, and as more fully described in this Agreement and this Work Order, InfoSpace will integrate the FlashCast Content on the FlashCast
Service as set forth in the FlashCast SOW. Other than the FlashCast Content, no other data, text or information will be integrated on the FlashCast Service. 

 

	3.3	Security Requirements. InfoSpace shall put in place and shall maintain commercially reasonable physical and electronic measures and operational procedures to
protect the security of the FlashCast Services and FlashCast Wireless Devices in order to (i) comply with Verizon Wireless’ security requirements as set forth in Exhibit S to the Agreement; and (ii) regularly monitor the Verizon
Wireless FlashCast Service and all connections between the Verizon Wireless Network and facilities or equipment controlled or maintained by InfoSpace. In the event InfoSpace becomes aware of any breach of security of the FlashCast Services or
FlashCast Wireless Devices, InfoSpace shall notify Verizon Wireless as provided in Attachment 2. 

  

	3.4	As between the Parties, Verizon Wireless shall have the sole right to adopt and communicate to Users statements about and descriptions of policies and practices related
to User privacy and the collection, storage and use of User Data. To the extent Verizon Wireless adopts new policies (i.e., following the Effective Date of the Second Amendment) with respect to User privacy and User Data, InfoSpace will comply with
such policies. ***. 

  

	3.5	Verizon Wireless may, at any time, request that InfoSpace make additions, deletions or other modifications to the FlashCast Services by submitting a Work Order,
substantially in the form of Exhibit E to the Agreement. All additions, deletions or other modifications to the FlashCast Services shall be handled pursuant to a mutually defined change process. 

 

	3.6	Capacity Forecast 

 To
ensure the highest level of service, Infospace requires Verizon Wireless at least *** to provide a forecast estimating the growth of their customer base *** and likely service usage. This will allow Infospace to plan the required resources to
support the services for Verizon Wireless’ customers. If Verizon Wireless becomes aware of any material changes that would impact any forecast previously provided to Infospace (e.g., if Verizon Wireless has a special promotion plan in which a
high number of new customers are anticipated for either a specified time period or for the remainder of the term), Infospace must be given *** advance notice of any change in the forecast to prepare for such additional capacity. If Verizon Wireless
fails to provide Infospace with such notice, for a period of *** following such increase Infospace will not be held responsible for any failures to the performance objectives that could have been avoided had Infospace received such notice. A
forecast provided pursuant to this section is only a forecast and is not a commitment on behalf of Verizon Wireless for the forecasted amount. 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 31 

	4.	FEES/PAYMENT 

  

	4.1	During the Term of this Work Order Wireless shall pay InfoSpace for the FlashCast Services in accordance with the rates set forth in Attachment 3. All payments are due
in U.S. Dollars. 

  

	4.2	In the event Verizon Wireless terminates services set forth in this Work Order for convenience prior to the FlashCast Launch Date as set forth in Section 2.1(d) of
the Second Amendment, InfoSpace shall immediately curtail all activities hereunder upon receipt of a notice of termination. Verizon Wireless’ sole liability to InfoSpace will be the payment of the unpaid balance of the Setup Fee, if any, and
all Monthly Sustainment Fees due through such date of termination and any other amounts (e.g., professional services fees) due InfoSpace for work completed before the date of termination by Verizon Wireless. InfoSpace shall invoice Verizon Wireless
for such fees and Verizon Wireless shall remit payment to InfoSpace in accordance with the Agreement. Verizon Wireless shall have no obligation or liability to InfoSpace for future monthly support fees, and if the charges for such cancelled Order
were paid in advance, InfoSpace shall promptly refund such charges to Verizon Wireless. For purposes of clarification, upon termination by Verizon Wireless of the FlashCast Services as set forth in this Section 4.2, InfoSpace shall be entitled
to retain 100% of the Setup Fee. 

  

	4.3	There shall be no charge to Verizon Wireless for the installation and implementation of the FlashCast Services except as set forth in Attachment 3. All Hardware (other
than equipment necessary for Infospace to provide telecommunications connectivity) required for the FlashCast Services as set forth in Schedule 1 will be owned by Verizon Wireless upon payment by Verizon Wireless of amounts due for such Hardware and
maintained by InfoSpace at a location owned or leased by InfoSpace (“InfoSpace Facilities”). Any dedicated connections (frame relay, VPN or otherwise) as may be required by Verizon Wireless for the connection between InfoSpace and Verizon
Wireless shall be procured and maintained at Verizon Wireless’ expense. 

  

	4.4	Verizon Wireless shall remit payment to InfoSpace in accordance with Section 3 of the Agreement. 

 

	4.5	InfoSpace shall not be responsible for the payment of any licensing fees associated with FlashCast Content. 

 

	5.	TESTING, EVALUATION AND APPROVAL. 

  

	5.1	Test Phones. Within *** of the Second Amendment Effective Date, Verizon Wireless will provide to InfoSpace *** pre-commercial test devices for each type of
FlashCast Wireless Device on which Verizon Wireless desires InfoSpace to make the FlashCast Services available on the FlashCast Launch Date. InfoSpace will use such devices for the purpose of testing the FlashCast Services and FlashCast Content
delivery to the FlashCast Wireless Devices. Any additional devices required beyond the initial test devices shall be 

  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 32 

	 	
procured at InfoSpace’s cost. To the extent Verizon Wireless desires InfoSpace to make the FlashCast Services available on any FlashCast Wireless Device(s) in addition to the devices
initially provided by Verizon Wireless within forty five (45) days of the Second Amendment Effective Date, Verizon Wireless will provide, *** test phones for each such additional device. Verizon Wireless shall deliver such additional test
device(s) at least *** in advance of the date that Verizon Wireless wishes the FlashCast Services to be made commercially available on such device. 

  

	5.2	Inspection and Approval. FlashCast Services will be subject to inspection by Verizon Wireless prior to the FlashCast Launch Date. During the Testing Period,
InfoSpace will provide Verizon Wireless access to the FlashCast Services in accordance with this Work Order and the Agreement. During the Testing Period, InfoSpace shall use its reasonable efforts to promptly correct any part of the FlashCast
Services that is within InfoSpace’s Span of Control, as defined in the SLA attached hereto as Attachment 2-A, that do not meet the specifications set forth in the FlashCast SOW or terms of this Agreement at its expense within *** of receipt of
written notice of nonconforming FlashCast Service from Verizon Wireless, or immediately following such notice if such nonconforming services are deemed by Verizon Wireless to cause an emergency condition. Verizon Wireless shall submit a written
acceptance or rejection of the FlashCast Services within *** of InfoSpace making the FlashCast Services available to Verizon Wireless for testing (the “Review Period”). If Verizon Wireless fails to submit a written acceptance or rejection
of the FlashCast Services within the Review Period, within *** after the Review Period, Infospace shall notify Verizon Wireless in writing, and Verizon Wireless shall have *** to respond. ***. To the extent Verizon Wireless rejects the FlashCast
Services (or any portion thereof), Verizon Wireless shall provide InfoSpace with a comprehensive list of any nonconforming component(s) of the FlashCast Services that it desires InfoSpace to remedy and InfoSpace shall do so as described above.
Acceptance of the FlashCast Services by Verizon Wireless shall be a condition precedent to the right of InfoSpace to receive payment of the Monthly Sustainment Fees specified in Attachment 3 ***. In addition to the foregoing, Infospace shall assist
Verizon Wireless as requested to complete the testing and acceptance process applicable to the Flashcast Software provided by ***, the third party responsible for developing and delivering the Flashcast Software to Verizon Wireless. InfoSpace may
require additional fees for such assistance. For the avoidance of doubt, to the extent Verizon Wireless elects not to launch the FlashCast Services, Verizon Wireless shall not be entitled to a refund of all, or any portion of, the Setup Fee.

  
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 33 

	5.3	Content Validation. After the FlashCast Launch Date InfoSpace shall test all existing Channels on one type of FlashCast Wireless Device for each display size
each day to ensure receipt of FlashCast Content and that the FlashCast Services operate in accordance with the FlashCast SOW. 

  

	5.4	Quality Assurance for Content. Verizon Wireless shall be responsible for all quality assurance testing of the FlashCast Content. Upon completion of such testing,
Verizon Wireless will supply the FlashCast Content, together with a certification of compliance, to InfoSpace for inclusion in the FlashCast Services in accordance with the FlashCast SOW. 

 

	5.5	Nonconformance After FlashCast Launch Date. After the FlashCast Launch Date, if the FlashCast Services do not conform to the FlashCast SOW, Verizon Wireless
shall be entitled to the remedies set forth in the Service Level Agreement set forth as Attachment 2-A. 

  

	5.6	Master Test Plan. In addition to the foregoing, the Master Test Plan, attached hereto as Attachment 4 shall apply. 

 

	6.	VERIZON WIRELESS’ PROPERTY. 

  

	6.1	Title 

 Title to all
materials and property Verizon Wireless provides to InfoSpace in connection with this Agreement shall remain in Verizon Wireless or, if applicable, its licensors or lessors. Any materials or property Verizon Wireless provides to InfoSpace, and any
materials or property of Verizon Wireless or its Users or Indirect Channel Entities that otherwise comes into InfoSpace’s possession or control in connection with the FlashCast Services shall be used only in the performance of this Agreement,
unless otherwise authorized in writing by Verizon Wireless. InfoSpace shall adequately protect all such material and property, and shall deliver or return it to Verizon Wireless or otherwise dispose of such property as directed by Verizon Wireless.
InfoSpace shall be responsible for any loss of or damage to materials or property owned by Verizon Wireless, or its licensors or lessors while in InfoSpace’s possession or control. 

Title to all materials and property InfoSpace provides to Verizon Wireless in connection with this Agreement shall remain in InfoSpace or,
if applicable, its licensors or lessors. Any materials or property InfoSpace provides to Verizon Wireless, and any materials or property of InfoSpace that otherwise comes into Verizon Wireless’ possession or control in connection with the
FlashCast Services shall be used only in the performance of this Agreement, unless otherwise authorized in writing by InfoSpace. Verizon Wireless shall adequately protect all such material and property, and shall deliver or return it to InfoSpace or
otherwise dispose of such property as directed by InfoSpace. Verizon Wireless shall be responsible for any loss of or damage to materials or property owned by InfoSpace, or its licensors or lessors while in Verizon Wireless’ possession or
control. 
  

 34 

	6.2	Hardware and Software. 

Verizon Wireless has obtained all necessary rights for InfoSpace to use the Hardware and Software set forth on Schedule 1 as contemplated
by this Work Order. Subject to the terms of this Work Order and the Agreement, Verizon Wireless hereby grants to InfoSpace a limited worldwide right and license to access and use the Hardware and Software for the sole purpose of providing the
FlashCast Services as provided herein. 
  

	6.3	Content 

  

	 	6.3.1.	FlashCast Content License. 

Verizon Wireless shall obtain all necessary rights for InfoSpace to use the FlashCast Content as described in this Work Order including
all attachments. Verizon Wireless grants to InfoSpace a limited, nonexclusive, non-transferable license to copy, store, display, transmit, distribute and sell FlashCast Content solely for the purpose of providing the Verizon Wireless Flashcast
Service to Users in accordance with this Agreement, expressly without the right of further sublicense of any of the foregoing. 
  

	 	6.3.2	Content License Restrictions.  

  

	 	6.3.2.1	Nothing in Section 6.3.1 above shall be interpreted as granting InfoSpace any greater rights or authorizations than are granted to Verizon Wireless pursuant to its
licensing agreements with Content Providers. InfoSpace shall have no right to reproduce or sub-license, re-sell or otherwise distribute all or any portion of FlashCast Content to any person in any form or any manner other than as necessary or
appropriate in providing access to the Verizon Wireless Flashcast Service in accordance with this Work Order, including its attachments, and the Agreement. 

 

	 	6.3.2.2	 Unless authorized by Verizon Wireless in writing, InfoSpace shall not alter or modify any FlashCast Content, engage in framing of FlashCast Content,
insert or allow or enable others to insert any pop-up windows, tool bars, consoles or other visual or audio items or use or allow or enable others to use any other techniques that alter the placement, appearance or presentation of FlashCast Content
on any Web Site or any FlashCast Wireless Device or the Verizon Wireless FlashCast Service. As used in this paragraph, “framing” means a method of constructing a web page such that the FlashCast Content within the frame may operate
independently of the content outside the frame, and “pop-up window” means a new window that contains content not expressly authorized or provided by Verizon Wireless that is launched on top of the FlashCast Content. 6.3.2.3 Subject to the
terms set forth in Section 4 and Exhibit S of the Agreement, except to the extent required to meet the specifications set forth in the FlashCast SOW, 

 

 35 

	 	
InfoSpace will not record, monitor or disclose any User’s use of any FlashCast Content unless instructed to do so in writing by Verizon Wireless, or as required by law, regulation, or court
order or as necessary to cooperate with a lawful order or demand of law enforcement officials. 

  

	 	6.3.2.3	Infospace shall use commercially reasonable efforts to ensure that no unauthorized third parties are able to gain access to and/or utilize the Verizon Wireless
Flashcast Service to generate and send content of any kind, including, but not limited to, unsolicited commercial messages. For purposes of this section, “commercially reasonable efforts” include, by way of example and not limitation, the
prompt removal by Infospace of any content it learns violates this section, with written notice to Verizon Wireless of such removal(s). 

  

	 	6.3.2.4	Infospace shall not itself place any advertisements on the FlashCast Services without the prior written consent of Verizon Wireless. For the avoidance of doubt, the
Parties acknowledge and agree that InfoSpace shall not control, nor be obligated to control, the content (including advertising content) provided to InfoSpace by Verizon Wireless or third parties at Verizon Wireless direction for distribution via
the FlashCast Services.  

  

	6.4	Work Product  

  

	 	6.4.1	InfoSpace agrees that the deliverables set forth in the FlashCast SOW, including but not limited to all notes, designs, reports and drafts thereof, constitute
“Verizon Wireless Work Product”. InfoSpace hereby agrees that all such Verizon Wireless Work Product are works made for hire exclusively for Verizon Wireless under the copyright laws of the United States and shall become and remain the
exclusive property of Verizon Wireless, and Verizon Wireless shall have the rights to use such for any purpose without any additional compensation to InfoSpace. 

 

	 	6.4.2	In the event any Verizon Wireless Work Product shall not be deemed to be a work made for hire exclusively for Verizon Wireless under the copyright laws of the United
States, InfoSpace hereby assigns and agrees to assign to Verizon Wireless its entire right, title and interest in and to (including the right to reproduce, modify, display, produce derivative works of, translate, publish, sell, use, dispose of, and
to authorize others so to do, and the right to copyright and to register such copyright in Verizon Wireless’ or its nominee’s name) all Verizon Wireless Work Product. InfoSpace further agrees to assist Verizon Wireless in every proper way
to protect Verizon Wireless Work Product, including, but not limited to, signing patent and copyright applications, oaths or declarations, and assignments in favor of Verizon Wireless relating to the 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 36 

 Work Product, as well as such ancillary and confirmatory documents as may be required or
appropriate to insure that such title is clearly and exclusively vested in Verizon Wireless, within the United States and in any and all foreign countries. InfoSpace further agrees to assist and cooperate with all efforts to enforce the rights of
Verizon Wireless in such property against any third parties. 
  

	 	6.4.3	Background Materials. Verizon Wireless acknowledges and agrees that Verizon Wireless Work Product does not include any Background Materials. InfoSpace hereby
grants Verizon Wireless a nonexclusive, royalty free, non-transferable, limited license to use the Background Materials set forth on Schedule 5 during the Term as necessary to use the Verizon Wireless Work Product in connection with the FlashCast
Services. To the extent that InfoSpace develops Verizon Wireless Work Product that requires the use of Background Materials in the future, InfoSpace will identify such Background Materials in the applicable Work Order and will grant Verizon Wireless
an appropriate license to use such Background Materials in connection with such Verizon Wireless Work Product. 

  

	 	6.4.4	InfoSpace warrants and represents that it has or will have the right, through written agreements with all employees performing FlashCast Services under or in connection
with this Agreement, to secure for Verizon Wireless the rights called for in this Section 6. Further, in the event InfoSpace uses any subcontractor, consultant or other third party to perform any of the Services contracted for by this
Agreement, InfoSpace agrees to enter into such written agreements with such third party, and to take such other steps as are or may be required to secure for Verizon Wireless the rights called for in this Section. 

 

	 	6.4.5	With the exception of the Verizon Wireless Work Product which shall be owned by Verizon Wireless as set forth above, the ownership of all Intellectual Property used or
developed by either Party in connection with the FlashCast Services shall be governed by Section 12.1 and Section 12.2 of the Agreement. 

  

	7.	USE OF MARKS. 

  

	7.1	Subject to the terms of Section 12.5 of the Agreement, InfoSpace hereby grants Verizon Wireless the personal, non-exclusive, limited-term, non-transferable
revocable (upon 30 days written notice) right to use, reproduce, publish and 

  

 37 

	 	
display the InfoSpace Trademarks in connection with the development, use, reproduction in promotional and marketing materials, FlashCast Content directories and indices, and electronic and
printed advertising, publicity, newsletters and mailings about Verizon Wireless and its relationship with InfoSpace. 

  

	7.2	Subject to the terms of section 12.5 of the Agreement Verizon Wireless hereby grants InfoSpace the personal, non-exclusive, limited-term, non-transferable, revocable
(upon 30 days written notice) right to use, reproduce, publish, and display Verizon Wireless Trademarks in connection with the provisioning of the FlashCast Services. 

 

	8.	Indemnification. 

 With
respect to the FlashCast Services, the following shall apply in place of Section 11.5 of the Agreement. 
 Indemnification

 (a) InfoSpace shall indemnify, defend and hold harmless Verizon Wireless, its parents, subsidiaries and Affiliates, and its
and their respective directors, officers, employees, and agents (“Verizon Indemnified Parties”) from any third party claims, demands, lawsuits, liabilities, expenses (including, but not limited to, reasonable fees and disbursements of
counsel and court costs), judgments, settlements (provided such settlements have been approved by InfoSpace) and penalties of every kind that may be (i) based on any material supplied by InfoSpace or its authorized representative with respect
to or in the Portal Services, excluding material supplied to InfoSpace by Verizon Wireless, including claims (A) arising from or relating to any actual or alleged infringement or misappropriation of any patent, trademark, copyright, trade
secret or any actual or alleged violation of any other intellectual property or proprietary rights arising from or in connection with any material or service supplied by InfoSpace with respect to the FlashCast Services (excluding the Hardware and
Software, unless such Claim arises from InfoSpace’s use of such Hardware or use of Software other than in accordance with the licenses granted) under this Work Order, (B) that InfoSpace is not the sole and exclusive owner of, or that it
does not have the express written right to the FlashCast Services and all other materials provided by InfoSpace under the terms of this Agreement, (C) that materials are factually inaccurate in any material respect, or (D) that materials
contain information, instructions or formulas that are injurious to a Third Party’s physical well-being, or that defames or disparages a Third Party, (ii) arising from any act or omission by InfoSpace or its authorized representative in
connection with its performance under this Work Order violates any applicable law or regulation; (iii) a claim that, if true, would constitute a breach of a warranty, representation or covenant of InfoSpace as set forth in this Agreement,
and/or (iv) a claim that InfoSpace has misused any Verizon Wireless User Data . The foregoing indemnification shall apply whether InfoSpace or a Verizon Indemnified Party defends such Claim and

  

 38 

 
whether the Claim arises or is alleged to arise out of the sole acts or omissions of InfoSpace (and/or any subcontractor of InfoSpace) or out of the concurrent acts or omissions of InfoSpace
(and/or any subcontractor of InfoSpace) and any Indemnified Parties. InfoSpace further agrees to bind its subcontractors, if any, to similarly indemnify, hold harmless, and defend the Indemnified Parties. 

(b) Without limitation of the foregoing, if sale, use or if applicable, distribution, of the products or FlashCast Services becomes
subject to an infringement Claim as set forth in subsection (i) above, InfoSpace shall, at InfoSpace’s option and InfoSpace’s expense,: 
  

	 	i.	Procure for Verizon Wireless the right to use the FlashCast Services (including related products furnished hereunder); 

 

	 	ii.	Replace the FlashCast Services (including related products furnished hereunder) with equivalent, non-infringing products and/or FlashCast Services; or

  

	 	iii.	Modify the FlashCast Services (including related products furnished hereunder) so they become non-infringing. 

 

	 	iv.	In the event that it is not commercially reasonable for InfoSpace to achieve (i), (ii) or (iii) above, InfoSpace may remove the infringing component(s) of the
FlashCast Services and refund the corresponding fees paid by Verizon Wireless to InfoSpace for such component(s). 

(c) Verizon Wireless shall indemnify, defend and hold harmless InfoSpace its parents, subsidiaries, and its and their respective
directors, officers, employees and agents (“Infospace Indemnified Parties”) from and against third party claims, demands, lawsuits, liabilities, expenses (including, but not limited to, reasonable fees and disbursements of counsel and
court costs), judgments and settlements (provided such settlements have been approved by Verizon Wireless) (i) arising from or relating to any actual or alleged infringement or misappropriation of any patent, trademark, copyright, trade secret
or any actual or alleged violation of any other intellectual property or proprietary rights arising from or in connection with the FlashCast Content and any other materials provided by Verizon Wireless for use in connection with the FlashCast
Services (including the Hardware and Software, except where Infospace is obligated to indemnify Verizon Wireless as set forth above), *** 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 39 

 
***. The foregoing indemnification shall apply whether Verizon Wireless or an Infospace Indemnified Party defends such Claim and whether the Claim arises or is alleged to arise out of the sole
acts or omissions of Verizon Wireless (and/or any subcontractor of Verizon Wireless) or out of the concurrent acts or omissions of Verizon Wireless (and/or any subcontractor of Verizon Wireless) and any Indemnified Parties. 

(d) For purposes of this subsection (d) Indemnifying Party shall mean the Party having indemnification obligations pursuant to
Sections 8(a) and/or 8(c) above and “Indemnified Party” shall mean as applicable, Verizon Indemnified Party or Infospace Indemnified Party. The Indemnified Party will provide the Indemnifying Party with prompt, written notice of any
written Claim covered by this indemnification and will cooperate appropriately with the Indemnifying Party in connection with its evaluation of such Claim. The Indemnifying Party shall defend any Indemnified Party, at the indemnified Party’s
request, against any Claim. Promptly after receipt of such request, the Indemnifying Party shall assume the defense of such Claim with counsel reasonably satisfactory to the Indemnified Party. In consultation with and subject to the approval of the
Indemnifying Party, the Indemnified Party shall have the right, to employ separate counsel to provide input into the defense, at the Indemnified Party’s own cost. The Indemnifying Party shall reimburse the Indemnified Party, ***, for any
payments made or loss suffered by it at any time after the date of tender, based upon the judgment of any court of competent jurisdiction or pursuant to a reasonable, good faith and bona fide compromise or settlement of claims, demands, or actions,
in respect to any damages to which the foregoing relates. The Indemnifying Party shall not settle or compromise any such Claim or consent to the entry of any judgment without the prior written consent of each Indemnified Party and without an
unconditional release of all claims by each claimant or plaintiff in favor of each Indemnified Party. 
  

	9.	Press Release. The Parties agree to issue, promptly upon the launch of the Verizon Wireless FlashCast Services, a joint press release announcing the launch of
the Verizon Wireless FlashCast Services and their relationship, provided that neither Party shall issue any such press release without the prior written consent of the other Party. Requests for consent of Verizon Wireless shall be sent to

 Vice President — Corporate Communications 

Verizon Wireless 

One Verizon Way 

VC43E062 

Basking Ridge, New Jersey 07920 
  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 40 

 List of Attachments, attached hereto and incorporated herein 

 

			
	 Attachment Reference
	  	 Attachment Name

	Attachment 1	  	Statement of Work
	Attachment 2-A	  	Network Service Level Agreement
	Attachment 2-B	  	Information Technology Service Level Agreement
	Attachment 2-C	  	Information Technology Interface Terms & Conditions
	Attachment 3	  	Pricing
	Attachment 4	  	Master Test Plan
	Attachment 5	  	FlashCast Release Process
	Attachment 6	  	Training
		
	Schedule 1	  	Hardware & Software Purchased by Verizon Wireless
	Schedule 2	  	Hardware & Software Purchased by InfoSpace
	Schedule 3	  	FlashCast Wireless Devices
	Schedule 4	  	Documentation
	Schedule 5	  	Background Materials

  

 41 

 Matter Number 710-30079-2007 

AMENDMENT NUMBER 3 

TO 

AGREEMENT NUMBER 750-67761-2004 

BETWEEN 

CELLCO PARTNERSHIP d/b/a VERIZON WIRELESS 

AND 

INFOSPACE MOBILE, INC. 

f/k/a PREMIUM WIRELESS SERVICES USA, INC. 

A WHOLLY OWNED SUBSIDIARY OF INFOSPACE, INC. 
  

	1.	PARTIES 

This Amendment Number 3 (“Third Amendment”) to the WAP 2.0 Hosting Agreement dated June 24, 2004, (as
amended, the “Agreement”), by and between InfoSpace Mobile, Inc. f/k/a Premium Wireless Services USA, Inc., a California corporation and wholly owned subsidiary of InfoSpace, Inc., with offices at 601
108th Avenue NE, Suite 1200, Bellevue, WA 98004
(“InfoSpace”) and Cellco Partnership d/b/a Verizon Wireless, a Delaware general partnership, having an office and principal place of business at One Verizon Way, Basking Ridge, NJ 07920 (“Verizon Wireless”), is made and entered
into on and as of the date of execution by the last signing Party (the “Third Amendment Effective Date”). 
  

	2.	AMENDMENT OF AGREEMENT. 

  

	a.	Exhibit A shall be amended by adding the following definitions: 

“Advertisement” shall mean a notice displayed as a banner on Phone Pages designed to attract public attention, or to
promote the sale of a product or service. 
 *** or *** means the Third Party providing Advertisements that
InfoSpace will make accessible through the Mobile Web 2.0 deck and display on Phone Pages in accordance with Work Order No. 29 agreed to by the parties on or about December 14, 2006. 

 

	b.	Section 1.4 (“Products and Services”) of Exhibit H-1 shall be amended by adding the following to Table 1 – Scope of Products and Services.

  

					
	***	  		  	
		  		  	

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 1 

 Matter Number 710-30079-2007 

 

	***	

 “*** System” means the
platform, including all hardware, software and associated networking capabilities, owned or licensed and used by *** to send the *** Content to the Phone Pages.  
  

	d.	The terms of Work Order No. 29 shall be modified, so as to provide additional clarification, as set forth below: 

 

	 	1.	All uses of the term “Ad” or “Ads” shall be deemed references to the term “Advertisement” as defined in the Agreement.

  

	 	2.	The term “Advertisement Id” shall mean the unique identifier assigned to a Phone Page hosted by InfoSpace. 

 

	 	3.	The phrase “Updating of *** Ads on Image Server” shall mean that InfoSpace shall provide *** write access to the *** Advertising Servers hosted at InfoSpace
in order to enable *** to update the available Advertisements. 

  

	 	4.	References to the term “Apps”, “applications” “application pages” and “pages” shall be deemed references to the term Phone Pages
as defined in the Agreement. 

  

	 	5.	The requirement that InfoSpace provide “Unique Ad Ids per Page” shall mean the obligation of InfoSpace to assign a unique Advertisement ID to each category of
Phone Page, to enable *** to identify the content and type of page in order to target the Advertisements to be sent to Subscribers by content type. 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 2 

 Matter Number 710-30079-2007 

 

	 	6.	Section 2, Requirements, of the SOW shall be modified by adding an introductory section as follows: 

In the initial deployment InfoSpace will host the *** Advertising servers within the same platform from which InfoSpace provides the WAP
2.0 Portal Service, as outlined in the diagram below. InfoSpace will host the *** servers at the InfoSpace’s Data Center until the InfoSpace Data Center is migrated to a new data center at the Savvis facility located in Boston,
Massachusetts. Following such migration, InfoSpace shall then connect to the *** System via a direct network connection located within the same data center. In the final deployment phase, the *** servers shall no longer be hosted on InfoSpace’s
premises. Verizon Wireless will obtain all necessary rights for InfoSpace to use the *** System as contemplated by this Work Order No. 29. 

The Advertisements will be provided by *** and InfoSpace shall provide *** with access to the Advertising Servers to enable *** to update
the available Advertisements as needed, subject to InfoSpace’s network security policies. InfoSpace shall work with *** and Verizon Wireless to ensure effective delivery of the Advertisements. InfoSpace shall also notify *** of any planned or
unplanned outages consistent with SLA notification procedures set forth in Exhibit H-1 of the Agreement. 
 Each time a
Subscriber requests a Phone Page view, InfoSpace will call the *** Advertising server, by invoking the *** API and *** will indicate which Advertisement to serve. Advertising images shall be retrieved dynamically for each Subscriber and InfoSpace
will place the *** designated Advertisement within the Phone Page the Subscriber requested to be served. 
 If InfoSpace does not
receive notification from *** within Verizon Wireless’ approved time-out period, InfoSpace shall serve a Verizon Wireless Advertisement, provided by Verizon Wireless (a “VZW House Ad”) instead. 

InfoSpace will provide monthly tracking of (i) how many *** Advertisements are served and (ii) how many times *** did not
respond within the Verizon Wireless approved time-out period resulting in InfoSpace providing a VZW house ad. InfoSpace shall provide the monthly tracking report to Verizon Wireless’ ASP Operations team and Technology Development. 

InfoSpace is not responsible for, and shall have no liability with respect to, any interruptions of service or any other performance
issues caused by *** or *** hardware and/or software. 
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 3 

 Matter Number 710-30079-2007 

*** 
  

	3.	EFFECT OF AMENDMENT. 

Unless otherwise explicitly amended herein, the terms and conditions of the Agreement shall remain in full force and effect. 

IN WITNESS WHEREOF, the undersigned have caused this Amendment Number 2 to be executed by their duly authorized representatives.

  

									
	 CELLCO PARTNERSHIP

d/b/a Verizon Wireless
	 		 	 INFOSPACE MOBILE, INC.

f/k/a Premium Wireless Services USA, Inc.
 A
Wholly Owned Subsidiary of InfoSpace, Inc.

					
	By:	 	***	 		 	By:	 	/s/ David Binder
	Name:	 	***	 		 	Name:	 	David Binder
	Title:	 	VP	 		 	Title: 	 	VP Finance
	Date:	 	11/20/07	 		 	Date:	 	11/19/07

  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 4 

 Contract Number: AGR-000431-2007 

AMENDMENT NUMBER 4 

TO 

AGREEMENT NUMBER 750-67761-2004 

BETWEEN 

CELLCO PARTNERSHIP d/b/a VERIZON WIRELESS 

AND 

INFOSPACE MOBILE, INC. 

f/k/a PREMIUM WIRELESS SERVICES USA, INC. 

A WHOLLY OWNED SUBSIDIARY OF INFOSPACE, INC. 

This Amendment Number 4 (“Fourth Amendment”) to the WAP 2.0 Hosting Agreement dated
June 24, 2004, as amended by the First Amendment to WAP 2.0 Hosting Agreement, dated August 31, 2004 and the Second Amendment to WAP 2.0 Hosting Agreement, dated April 4, 2007, and the Third Amendment to WAP 2.0 Hosting Agreement,
dated November 20, 2007 by and between InfoSpace Mobile, Inc. f/k/a Premium Wireless Services USA, Inc., a California corporation and wholly owned subsidiary of InfoSpace, Inc., with offices at 601
108th Avenue NE, Suite 1200, Bellevue, WA 98004
(“InfoSpace”) and Cellco Partnership d/b/a Verizon Wireless, a Delaware general partnership, having an office and principal place of business at One Verizon Way, Basking Ridge, NJ 07920 (“Verizon Wireless”) (as
amended, the “Agreement”), is by and between InfoSpace, Motricity, Inc., a Delaware corporation, with offices at 210 West Pettigrew Street, Durham, NC 27701 (“Motricity”) and Verizon Wireless, and is made and
entered into on and as of the last date signed by the parties hereto.  
 WHEREAS, InfoSpace, Inc. and Motricity
are entering into an Asset Purchase Agreement pursuant to which certain assets of InfoSpace, including the Agreement, are expected to be transferred to Motricity (the “Transaction”); 

WHEREAS, upon the closing of the Transaction, Motricity wishes to assume the rights, and obligations of InfoSpace under the
Agreement arising after the closing of the Transaction and to continue to provide the Portal Services to Verizon Wireless in accordance with the terms and conditions of the Agreement; 

WHEREAS, all liabilities prior to the closing of the Transaction shall remain with InfoSpace; and 

WHEREAS, upon the closing of the Transaction, Verizon Wireless wishes InfoSpace to assign the Agreement to Motricity and for
Motricity to replace InfoSpace as the contracting entity to the Agreement. 
 NOW, THEREFORE, in consideration of the
foregoing, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties agree as follows: 

1. Assignment. Subject to the closing of the Transaction and effective as of the closing date of the Transaction (the “Transaction Closing
Date”), InfoSpace hereby assigns to Motricity, and Motricity hereby accepts, all of InfoSpace’s rights, title and interest in and to the 

 

 1 

 Contract Number: AGR-000431-2007 

 

 
Agreement. In addition, Motricity hereby assumes all of the obligations duties, responsibilities and undertakings to be performed by InfoSpace under the Agreement occurring, arising, accruing or
to be accrued from and as of the Transaction Closing Date (the “Assumed Obligations”) and shall fully and timely perform all of the Assumed Obligations in accordance with the Agreement. Verizon Wireless hereby waives all claims
against InfoSpace in connection with the Agreement that arise on or after the Transaction Closing Date. InfoSpace represents and acknowledges that it is and shall remain responsible for all matters, of whatever type or character, occurring, arising,
accrued or to accrue under the Agreement on or before the Transaction Closing Date and that Verizon Wireless’ consent is without prejudice to any claim pertaining to such matters. 

2. Amendment to Agreement. As of the Transaction Closing Date, the Parties hereby agree that Motricity shall replace InfoSpace as the contracting
entity to the Agreement and all references to “InfoSpace Mobile, Inc.” or “InfoSpace” shall be deleted and replaced with “Motricity, Inc.” or “Motricity”, respectively. In the event that the Transaction does
not close, the Parties agree that this Fourth Amendment shall be of no force or effect. 
 3. Effect of Amendment. This Fourth Amendment
is an integral part of the Agreement. Terms used herein which are defined or specified in the Agreement shall have the meanings set forth therein. If there are any inconsistencies between a specific term or condition of this Fourth Amendment and a
specific term or condition of the Agreement, the specific term or condition of this Fourth Amendment shall control, but only to the extent of such inconsistencies. Except as amended hereby, the Agreement shall continue in full force and effect.

 SIGNATURES. 
 IN
WITNESS WHEREOF, the Parties hereto have caused this Third Amendment to be executed by their duly authorized officers or representatives. 
  

									
	 CELLCO PARTNERSHIP d/b/a

Verizon Wireless
	 		 	INFOSPACE MOBILE, INC.
					
	By:	 	***	 		 	By:	 	/s/ David Binder
	Name:	 	***	 		 	Name:	 	David Binder
	Title:	 	VP	 		 	Title: 	 	VP Finance
	Date:	 	11/20/2007	 		 	Date:	 	11/19/2007

  

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 2 

 Contract Number: AGR-000431-2007 

 

			
	MOTRICITY, INC.
		
	By:	 	/s/ Ryan K. Wuerch
	Name:	 	Ryan K. Wuerch
	Title:	 	CEO
	Date:	 	11/17/2007

  

 3 

 Matter Number: AGR-001660-2009 

AMENDMENT NUMBER 5 

TO 

AGREEMENT NUMBER 750-67761-2004 

BETWEEN 

CELLCO PARTNERSHIP d/b/a VERIZON WIRELESS 

AND MOTRICITY, INC. 

This Amendment Number 5 (the “Fifth Amendment”) to the WAP 2.0 Hosting Agreement dated June 24, 2004, as amended by the
First Amendment to WAP 2.0 Hosting Agreement, dated August 31, 2004, the Second Amendment to WAP 2.0 Hosting Agreement dated May 14, 2007, the Third Amendment to WAP 2.0 Hosting Agreement dated November 20, 2007, and the Fourth
Amendment to WAP 2.0 Hosting Agreement dated November 20, 2007 (as amended, (the “Agreement”), by and between Motricity, Inc., a Delaware corporation, with offices at 601 108th Avenue NE, Suite 900, Bellevue, WA 98004
(“Motricity”) and Cellco Partnership d/b/a/ Verizon Wireless, a Delaware general partnership, having an office and principal place of business at One Verizon Way, Basking Ridge, NJ 07920 (“Verizon Wireless”), is made and entered
into on and as of the date of execution by the last signing Party but taking retroactive effect to and including December 1, 2008 (“Effective Date”). 
  

	1.	AMENDMENT OF AGREEMENT. 

  

	1.1	The purpose of this Fifth Amendment is to modify the Page View forecast set forth in Table 2 of Section 3(1) of revised Exhibit D as set forth in the Second
Amendment (#710-30429-2007) to the Agreement. 

  

	1.2	The aforementioned Table 2 is hereby deleted in its entirety and replaced with the following: 

 

					
	 ***
	  	***	  	***
	4Q06	  	***	  	***
	1Q07	  	***	  	***
	2Q07	  	***	  	***
	3Q07	  	***	  	***
	4Q07	  	***	  	***
	1Q08	  	***	  	***
	2Q08	  	***	  	***
	3Q08	  	***	  	***
	4Q08	  	***	  	***
	1Q09	  	***	  	***
	2Q09	  	***	  	***
	3Q09	  	***	  	***
	4Q09	  	***	  	***
	1Q10	  	***	  	***

 *** 

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 1 

 Matter Number: AGR-001660-2009 

 

	2.	EFFECT OF AMENDMENT. 

This Fifth Amendment is an integral part of the Agreement. Terms used herein which are defined or specified in the Agreement shall have
the meanings set forth therein. If there are any inconsistencies between a specific term or condition of this Fifth Amendment and a specific term or condition of the Agreement, the specific term or condition of this Fifth Amendment shall control.

 Except as amended hereby, the Agreement shall continue in full force and effect. 

 

	3.	SIGNATURES. 

 IN WITNESS
WHEREOF, the parties hereto have caused this Amendment to be executed by their duly authorized officers or representatives. 
  

									
	 CELLCO PARTNERSHIP d/b/a

Verizon Wireless
	 		 	Motricity, Inc.
					
	By:	 	***	 		 	By:	 	/s/ Ryan Wuerch
	Name: 	 	***	 		 	Name: 	 	Ryan Wuerch
	Title:	 	***	 		 	Title: 	 	Chairman & CEO
	Date:	 	10/2/2009	 		 	Date:	 	4/22/2009

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 2 

 Matter Number: AGR-001660-2009 

AMENDMENT NUMBER 6 

TO 

AGREEMENT NUMBER 750-67761-2004 

BETWEEN CELLCO PARTNERSHIP d/b/a VERIZON WIRELESS 

AND 

MOTRICITY, INC 

This Amendment Number 6 (“Sixth Amendment”) to the WAP 2.0 Hosting Agreement dated June 24, 2004, as
amended by the First Amendment, dated August 31, 2004 and the Second Amendment, dated May 14, 2007, and the Third Amendment, dated November 20, 2007 and the Fourth Amendment, dated November 20, 2007 and the Fifth Amendment, dated
June 13, 2009 (as amended, the “Agreement”), by and between Motricity, Inc. a Delaware corporation, with offices at 601
108th Avenue NE, Suite 900, Bellevue, WA
(“Motricity”) and Cellco Partnership d/b/a Verizon Wireless, A Delaware general partnership, having an office and principal place of business at One Verizon Way, Basking Ridge, NJ 07920 (“Verizon Wireless “), is made and entered
into on and as of the date of execution by the last signing Party (“Sixth Amendment Effective Date”). 
  

	1.	AMENDMENT OF AGREEMENT. 

  

	 	1.1	Section 8.1 of the Agreement “Term” shall be deleted in its entirety and replaced with the follows: 

“Term. The term of this Agreement shall commence on the Effective Date and unless earlier terminated pursuant to the terms of this Agreement, shall
end July 31, 2010 (the “Term”). The Term shall be automatically renewed for successive 6-month periods unless either Party provides written notice of termination to the other Party at least sixty (60) days prior to the end of the
Term or any subsequent renewal period.” 
  

	 	1.2	A new Section B.2 is added as follows: 

  

	 	2.	SELF-HOSTING 

 Upon *** prior
written notice to Motricity, and subject to the execution of a mutually agreed license agreement, which may be in the form of an amendment to this Agreement, Verizon Wireless, may elect to host the Motricity proprietary software that supports the
Portal Services at one or more facilities maintained by Verizon Wireless (“Self-Host”). If Verizon Wireless elects to Self-Host it will be responsible for all expenses associated with procuring the necessary hardware and third party
software and all expenses associated with licensing, installing, configuring, and operating the Motricity software. The transition of hosting will be performed by the parties in accordance with a schedule and commercial terms to be mutually agreed
in a Work Order. 
  
  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 1 

 Matter Number: AGR-001660-2009 

 

 Within *** of receiving Verizon Wireless’ notice of its desire to Self-Host,
Motricity will deliver a list of Motricity proprietary software components to be licensed. Verizon Wireless acknowledges that its ability to Self-Host and make Portal Services available to users may be subject to Verizon Wireless’ ability to
obtain sufficient rights in third party technology (such as any third-party software used in connection with the hosting), content and applications. 

The parties shall endeavor to negotiate a license agreement for the software within *** of Verizon Wireless’ notice. The license will
include the right to use the software in object code only. Each party shall use good faith efforts to reach agreement on licensing terms. If the parties cannot reach agreement, this Agreement will remain in effect unless terminated in accordance
with its terms. 
  

	2.	EFFECT OF AMENDMENT. 

 This Sixth
Amendment is an integral part of the Agreement. Terms used herein which are defined or specified in the Agreement shall have the meanings set forth therein. If there are any inconsistencies between a specific term or condition of this Sixth
Amendment and a specific term or condition of the Agreement, the specific term or condition of this Sixth Amendment shall control. Except as amended hereby, the Agreement shall continue in full force and effect. 

 

	3.	SIGNATURES. 

 IN WITNESS WHEREOF,
the Parties hereto have caused this Sixth Amendment to be executed by their duly authorized officers or representative 
  

									
	 CELLCO PARTNERSHIP d/b/a

VERIZON WIRELESS
	 		 	MOTRICITY, INC
					
	BY:	 	***	 		 	BY:	 	/s/ Ryan Wuerch
	NAME: 	 	***	 		 	NAME: 	 	Ryan Wuerch
	TITLE:	 	***	 		 	TITLE:	 	Chairman & CEO
	DATE:	 	10/2/2009	 		 	DATE:	 	8/21/2009

 

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 2 

 Matter Number 710-30079-2007 

FORM OF WORK ORDER 

Work Order No. 84 

to WAP 2.0 Hosting Agreement 

Motricity Inc., (“Motricity”) will perform the following additional Portal Services for Cellco Partnership d/b/a Verizon Wireless
(“Verizon Wireless”) under the terms and conditions of that certain WAP 2.0 Hosting Agreement, Contract No. 750-67761-2004, dated 6/24/04, as amended, between Motricity and Verizon Wireless (the “Agreement”). In
consideration of the additional Portal Services described below, Verizon Wireless will pay to Motricity the amount(s) set forth below on or before the date(s) set forth below. 

 

							
	 Task Description - Mobile Web 3.0 User Subscription Fee
	  	Target Date
	 Motricity shall provide access to the Mobile Web 3.0 Portal Services provided by Motricity to Verizon Wireless under Work
Order No. 77. Such services shall be referred to herein as the “Mobile Web 3.0 Portal Services.”
  

Motricity agrees to provide access to the Mobile Web 3.0 Portal Services per the volume schedule below:

 
 Launch Internet Explorer Browser.lnk
	  	Production launch
targeted on or before
Sept 8th, 2009.
				
	 Month
	  	 Maximum Users
	  	 	  	 
	October 2009	  	***	  		  	
	November 2009	  	***	  		  	
	December 2009	  	***	  		  	
	January 2010	  	***	  		  	
	February 2010	  	***	  		  	
	March 2010	  	***	  		  	
	April 2010	  	***	  		  	
	May 2010	  	***	  		  	
	June 2010	  	***	  		  	
	July 2010	  	***	  		  	
	August 2010	  	***	  		  	
	Sept 2010	  	***	  		  	
		
	 For purposes of this Work Order No. 84, a User is defined as a unique subscriber, as identified by his/her Mobile
Directory Number (“MDN”), who has accessed the Mobile Web 3.0 Portal Services provided as part of Work Order 77 during a calendar month of the Term.
  

Unforseen Volume Protection. In the case the actual Users in a given month exceeds the Maximum users forecast in the table above, the parties agree
to work together in good faith to agree upon terms for supporting the incremental Users.
	  	

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 1 

 Matter Number 710-30079-2007 

 

							
	 Amount:
	  	Payment Terms:
	In consideration for Motricity providing Users with access to the Mobile Web 3.0 Portal Services, Verizon Wireless shall pay Motricity the subscription fees outlined
below for each calendar month during the Term that the Mobile Web 3.0 Portal Services are made available under Work Order No. 77 (“User Subscription Fee”). For clarity, the User Subscription Fee is not an additional hosting fee as
described in Section 8, Exhibit D of the Agreement, but provides a term license to Motricity’s Mobile Web 3.0 Portal Services.	  	In accordance with Section 3 Payments of the Agreement
	 	  	 Month
	  	Monthly User
Subscription Fee	  	 
		  	Launch through December 2009	  	***	  	
		  	January through April 2010	  	***	  	
		  	May through July 31, 2010	  	***	  	
			
		  	 Motricity shall invoice Verizon Wireless the user Subscription Fee following each calendar month of the Term that the Mobile
Web 3.0 Portal Services are made available, and Verizon Wireless shall pay such invoice in accordance with the terms and conditions set forth in the Agreement.
  

Motricity shall commence invoicing Verizon Wireless the User Subscription Fee following the delivery of the Mobile Web 3.0 Portal Services described in
Work Order 77.
	  	

  

					
	CELLCO PARTNERSHIP d/b/a Verizon Wireless	 		 	Motricity, Inc.
			
	***	 		 	/s/ Ryan Wuerch
	By (signature)	 		 	By (signature)
	***	 		 	Ryan Wuerch
	Name	 		 	Name
	Executive Director	 		 	Chairman & CEO
	Title	 		 	Title

  

	***	This redacted material has been omitted pursuant to a request for confidential treatment, and the material has been filed separately with the Commission.

  

 2

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00172-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00172-of-00352.parquet"}]]