Document:

Facility Agreement

 Exhibit 10.1 
 DATED 27 June 2008 
 FACILITY AGREEMENT 
 For 
 SAVVIS UK LIMITED

 as Borrower 
 with 

 SAVVIS, INC. 
 as
Guarantor 
 and 
 LOMBARD NORTH CENTRAL PLC 
 as Lender 
  

 i 

 CONTENTS 
  

					
	SECTION 1 INTERPRETATION	  	1
	1	  	DEFINITIONS AND INTERPRETATION	  	1
	SECTION 2 THE FACILITIES	  	17
	2	  	THE FACILITY	  	17
	3	  	PURPOSE	  	17
	4	  	CONDITIONS OF UTILISATION	  	17
	5	  	UTILISATION OF POWER LOANS	  	18
	SECTION 3 UTILISATION	  	19
	6	  	UTILISATION	  	19
	SECTION 4 REPAYMENT, CANCELLATION AND EARLY CANCELLATION	  	20
	7	  	REPAYMENT	  	20
	8	  	PREPAYMENT, CANCELLATION AND EARLY TERMINATION	  	20
	SECTION 5 COSTS OF UTILISATION	  	24
	9	  	INTEREST	  	24
	10	  	COMMERCIAL LOAN PERIOD SWAP RATE AND REPAYMENT SCHEDULE	  	26
	11	  	POWER LOAN PERIOD SWAP RATE AND REPAYMENT SCHEDULE	  	26
	12	  	HEDGING	  	27
	13	  	THE INTEREST PERIOD	  	28
	14	  	CHANGES TO THE CALCULATION OF INTEREST	  	28
	15	  	ARRANGEMENT FEE	  	30
	SECTION 6 ADDITIONAL PAYMENT AND PREPAYMENT OBLIGATIONS	  	31
	16	  	TAX GROSS UP AND INDEMNITIES	  	31
	17	  	INCREASED COSTS	  	32
	18	  	OTHER INDEMNITIES	  	34
	19	  	MITIGATION BY THE LENDER	  	35
	20	  	COSTS AND EXPENSES	  	35
	SECTION 7 GUARANTEE	  	37
	21	  	GUARANTEE AND INDEMNITY	  	37
	SECTION 8 REPRESENTATIONS, UNDERTAKINGS AND EVENTS OF DEFAULT	  	40
	22	  	REPRESENTATIONS	  	40
	23	  	INFORMATION UNDERTAKINGS	  	45
	24	  	FINANCIAL COVENANTS	  	47
	25	  	LETTER OF CREDIT	  	48
	26	  	[DELIBERATELY LEFT BLANK]	  	51
	27	  	GENERAL UNDERTAKINGS	  	51
	28	  	SPECIFIC UNDERTAKINGS	  	54
	29	  	INSURANCE UNDERTAKINGS	  	57
	30	  	EVENTS OF DEFAULT	  	60
	SECTION 8 CHANGES TO PARTIES	  	65
	31	  	ASSIGNMENT BY THE LENDER	  	65
	32	  	CHANGES TO THE OBLIGORS	  	65
	SECTION 10 ADMINISTRATION AND INDEMNITIES	  	66
	33	  	PAYMENT MECHANICS	  	66
	34	  	SET-OFF	  	68
	35	  	NOTICES	  	68
	36	  	CALCULATIONS AND CERTIFICATES	  	69
	37	  	CONDUCT OF BUSINESS BY THE LENDER	  	70
	38	  	PARTIAL INVALIDITY	  	70
	39	  	REMEDIES AND WAIVERS	  	70
	40	  	AMENDMENTS AND WAIVERS	  	70

  

 ii 

					
	41	  	COUNTERPARTS	  	70
	42	  	GOVERNING LAW	  	70
	43	  	ENFORCEMENT	  	71
	44	  	AGENT FOR SERVICE OF PROCESS	  	71

  

					
	SCHEDULE 1	  	The Parties	  	71
	Part I The Borrower	  	71
	Part II SAVVIS, Inc.	  	71
	Part III The Lender	  	71
	SCHEDULE 2	  		  	72
	Part I Initial Conditions Precedent	  	72
	Part II Further Conditions Precedent	  	74
	SCHEDULE 3	  	Utilisation Request	  	75
	SCHEDULE 4	  	Mandatory Cost formula	  	76
	SCHEDULE 5	  	Repayment Schedule	  	78
	SCHEDULE 6	  	Contents of Management Report	  	80
	SCHEDULE 7	  	Works Schedule and expected Drawdown Schedule	  	81
	SCHEDULE 8	  	Original Letter of Credit	  	82

  

 iii 

 DATED 27 June 2008 
 PARTIES 
  

	(1)	SAVVIS UK LIMITED, a private limited company incorporated under the laws of England and Wales with registration number 03816299, and having its registered office at Eskdale
Road, Winnersh Triangle, Wokingham, Berkshire RG41 5TS (the “Borrower”); 

  

	(2)	SAVVIS, INC., a Delaware Corporation (“SAVVIS, Inc.”) 

  

	(2)	Lombard North Central Plc, a company incorporated under the laws of England and Wales with registered number 00337004 and having its registered office at 3 Princess Way,
Redhill, Surrey RH1 1NP (the “Lender”); 

 BACKGROUND 
 The Lender has agreed to make available to the Borrower a term loan facility of up to £35,000,000 on the terms set out herein. 
 OPERATIVE PROVISIONS 
 SECTION 1 
 INTERPRETATION 
  

	1	DEFINITIONS AND INTERPRETATION 

  

	1.1	Definitions 

 In this Agreement: 
 “Additional Cost Rate” has the meaning given to it in Schedule 4. 
 “Advance” means a certain amount of the Facility drawn down by the Borrower pursuant to the terms of this Agreement. 
 “Affiliate” means, in relation to any person, a Subsidiary of that person or a Holding Company of that person or any other Subsidiary of
that Holding Company. 
 “Applicable Law” means (without any limitation whatsoever): 
  

	 	(a)	any common or customary law, constitution, code, decision, decree, judgment, legislation, international law, order, ordinance, regulation, statute, treaty, any legislative measure,
act, procedure, rule, statutory instrument, proclamation, by-law or similar instrument or matter, present or future directive, regulation, guideline, practice, concession, request or requirement whether or not having the force of law (but if not
having the force of law, something with which it is customary for businesses similar to the Borrower’s business to comply) issued by (or on behalf of) any Government Entity, governmental body, agency or department or any central bank or other
fiscal, monetary, regulatory, self regulatory or other authority or agency (as any of the foregoing may be amended, substituted, varied and/or consolidated from time to time); and/or 

  

 1 

	 	(b)	any final judgment, order, determination or award of any court, arbitral body, administrative body or tribunal from which there is no right of appeal or if there is a right of
appeal such appeal is not pursued within the allowable time, 

 wheresoever applicable and/or relevant. 
 “Approved Brokers” means such firm or firms of insurance brokers as approved in writing by the Lender (such approval not to be
unreasonably withheld or delayed). 
 “Approved Insurer” means such insurance companies with an A.M. Best rating of
“A” or with respect to insurance companies providing earthquake insurance, an A.M. Best rating of “A-”. 
 “Arrangement Fee” means the fee payable in accordance with Clause 15. 
 “Asset Security Agreement”
means the security agreement executed by the Borrower and SAVVIS, Inc. over the Data Centre Assets and the Insurances in favour of the Lender. 
 “Authorisation” means an authorisation, consent, approval, resolution, licence, exemption, filing, notarisation, legalisation or registration. 
 “Availability Period” means the period from and including the date of this Agreement to and including 30 June 2009 or such other period as may be agreed at the sole discretion of the Lender.

 “Available Commitment” means, the Total Commitment minus: 
  

	 	(a)	the amount of any Advance(s); and 

  

	 	(b)	in relation to any proposed Utilisation, the amount of any Advance(s) which is (or are) due to be made on or before the related proposed Utilisation Date. 

“Borrower’s Business Forecast for Slough” means the business forecast provided by the Borrower to the Lender dated
20 February 2008 showing, amongst other things, the Borrower’s projected capital expenditure on and expected earnings from the Slough Data Centre. 
 “Borrower’s Business Report for Slough” means a report in exactly the same form as the Borrower’s Business Forecast for Slough demonstrating whether or not the LC Release Amount has been
achieved by the date of such report to be delivered by the Borrower to the Lender in accordance with Clause 25. 
 “Break
Costs” means, in the event of a termination or cancellation of the Loan or Loans (for whatever reason) or the non-receipt of any Unpaid Sum, 
  

	 	(a)	during the Construction Period and thereafter if the Borrower does not make the election pursuant to Clause 9.4.5, the amount (if any) by which 

  

	 	(i)	the interest, excluding the Margin, which the Lender should have received hereunder for the period from the date of receipt of all or any part of the Loan or that Unpaid Sum to the
last day of the current month for which monthly LIBOR has been calculated during the relevant Interest Period in respect of the Loan or that Unpaid Sum, had the amount of the Loan or that Unpaid Sum received been paid on the last day of that
Interest Period, exceeds 

  

 2 

	 	(ii)	the amount which the Lender would be able to obtain by placing an amount equal to the amount of the Loan or Unpaid Sum received by it on deposit with a leading bank in the London
interbank market for a period starting on the Business Day following receipt or recovery and ending on the last day of the current month for which monthly LIBOR has been calculated during the relevant Interest Period; and 

 

	 	(b)	if the Borrower makes the election pursuant to Clause 9.4.5, in respect of the Commercial Loan, during the Commercial Loan Period or, in respect of the Power Loan, during the Power
Loan Period, any claim, expense, liability or loss, including a loss of a prospective profit, incurred by the Lender: 

  

	 	(i)	in liquidating or employing deposits from third parties acquired or arranged to fund or maintain all or any part of the Loan or Loans and/or any Unpaid Sum; and

  

	 	(ii)	in terminating, or otherwise in connection with, any interest and/or currency swap and/or any other transaction entered into (whether with another legal entity or another office or
department of the Lender) to hedge any exposure arising under this Agreement or that part which the Lender determines is fairly attributable to this Agreement of the liabilities, expenses or losses (including losses of prospective profits) incurred
by it in terminating or otherwise in connection with a number of transactions of which this Agreement is one. 

 “Break
Gains” means, in the event of a termination or cancellation of the Loan(s) (for whatever reason): 
  

	 	(a)	during the Construction Period in respect of the Commercial Loan and the Power Loan Construction Period in respect of the Power Loan, and thereafter, if the Borrower does not make
the election pursuant to Clause 9.4.5, the amount (if any) by which: 

  

	 	(i)	the amount which the Lender would be able to obtain by placing an amount equal to the principal amount received by it on deposit with a leading bank in the London Interbank Market
for a period starting on the Business Day following receipt and ending on the last day of the current month for which monthly LIBOR has been calculated during the relevant Interest Period; 

 exceeds: 
  

	 	(ii)	the interest (excluding the Margin) which the Lender should have received hereunder for the period starting on the date of receipt of all or any part of the Loan and ending on the
last day of the current Interest Period in respect of the Loan, had the principal amount received been paid on the last day of the month for which monthly LIBOR has been calculated during the relevant Interest Period ; and 

 

	 	(b)	if the Borrower makes the election pursuant to Clause 9.4.5, during the Commercial Loan Period, or any Power Loan Period, any gain achieved by the Lender: 

 

	 	(i)	in liquidating or employing deposits from third parties acquired or arranged to fund or maintain all or any part of the Loan; or 

  

 3 

	 	(ii)	in terminating or otherwise in connection with, any interest and/or currency swap and/or any other transaction entered into (whether with another legal entity or another office or
department of the Lender) to hedge any exposure arising under this Agreement or that part which the Lender determines is fairly attributable to this Agreement of the gains achieved by it in terminating or otherwise in connection with a number of
transactions of which this Agreement is one. 

 “Business” means the operation of the Data Centres. 

“Business Day” means a day (other than a Saturday or Sunday) on which banks are open for general business in London. 
 “Class A Data Centre Assets” has the meaning given to it in the Asset Security Agreement. 
 “Commercial Loan” means the principal amount outstanding from time to time under this Agreement during the Commercial Loan Period.

 “Commercial Loan Period” means a period of no more than sixty months commencing on the Construction Period End Date and
ending on the Termination Date. 
 “Commercial Loan Period Swap Rate” means the rate calculated in accordance with Clause 10.

 “Contractors” means those persons, other than the Borrower, which are party to the Construction Contracts. 
 “Construction Contracts” means all those contracts or documents from time to time entered into by or granted to, inter alia, the Borrower
in connection with and necessary for the structure, construction, design, installation, commissioning and fit out of the Slough Data Centre including, without limitation, professional team appointments, construction contracts, guarantees,
performance bonds, collateral warranties and bonds. 
 “Construction Period” means the period from the date of this Agreement
to the earlier of: 
  

	 	(a)	1 October 2008, being the date specified in the Works Schedule as the date when the project at the Slough Data Centre is due to be completed or, if the Works Schedule is deemed
to be amended in accordance with Clause 23.4.3, such later date as may be agreed in accordance with that Clause; and 

  

	 	(b)	the date the Lender is satisfied (acting reasonably) that all the Milestones have been achieved. 

 “Construction Period End Date” means the earlier to occur of : 
  

	 	(a)	the last day of the Availability Period; and 

  

	 	(b)	the last day of the Construction Period. 

 “Data
Centre Assets” means all electrical, power, cooling and other critical infrastructure and all IT equipment and servers located at the Data Centres which are the subject of (and more particularly described in) the Asset Security Agreement
from time to time and all replacements thereto which may be made in accordance with this Agreement or the Asset Security Agreement. 
  

 4 

 “Data Centres” means the Slough Data Centre, the Winnersh Data Centre and the Docklands
Data Centre. 
 “Default” means an Event of Default or a Potential Event of Default. 
 “Disruption Event” means either or both of: 
  

	 	(a)	a material disruption to those payment or communications systems or to those financial markets which are, in each case, required to operate in order for payments to be made in
connection with the Facility (or otherwise in order for the transactions contemplated by the Finance Documents to be carried out) which disruption is not caused by, and is beyond the control of, any of the Parties; or 

  

	 	(b)	the occurrence of any other event which results in a disruption (of a technical or systems-related nature) to the treasury or payments operations of a Party preventing the Lender,
or any other Party: 

  

	 	(i)	from performing its payment obligations under the Finance Documents; or 

  

	 	(ii)	from communicating with other Parties in accordance with the terms of the Finance Documents, 

 and which (in either such case) is not caused by, and is beyond the control of, the Party whose operations are disrupted. 
 “Docklands Data Centre” means the Borrower’s Data Centre at Greenwich View Place, Millharbour, London. 
 “Early Termination Date” means the date identified in any notice issued pursuant to Clause 8.3 
 “Environmental Approval” means any present or future permit, licence, approval, consent, ruling, variance, exemption or other
authorisation required under Environmental Laws in connection with the Security Assets. 
 “Environmental Claim” means any
claim by any governmental, judicial or regulatory authority or any other person which arises out of an Environmental Incident or an alleged Environmental Incident, an actual or alleged breach of any Environmental Law, or which relates to any
Environmental Law (including any law relating to radioactive material), and for this purpose “claim” means a claim for damages, compensation, contribution, loss, injury or death, fines, penalties or any other payment of any kind
including in relation to clean-up and removal, an order or direction to take, or not to take, certain action or to desist from or suspend certain action and any form of enforcement or regulatory action. 
 “Environmental Incident” means any release, emission, spill or discharge of Environmentally Sensitive Material in connection with any
Data Centre into or upon the air, surface water, ground water or soils (including the seabed) for which the Borrower and/or any contractor, sub-contractor, operator or manager, if any, of a Data Centre is liable or may have liability under or
pursuant to Environmental Laws other than in accordance with any applicable Environmental Approval. 
  

 5 

 “Environmental Law” means any Applicable Law relating to pollution, safety or protection
of human health or the environment, to the use, production, reduction, mixing, handling, keeping, storing, disposal, transport or carriage of Environmentally Sensitive Material or to actual or threatened releases of Environmentally Sensitive
Material. 
 “Environmentally Sensitive Material” means and includes all pollutants, contaminants, toxic and radioactive
substances, oil, oil products and any other substance (including any chemical, gas or other hazardous or noxious substance) which is (or is capable of being or becoming) polluting, toxic, radioactive or hazardous. 
 “Event of Default” means any event or circumstance specified as such in Clause 30. 
 “Facility” means the Loan or Loans made available under the terms of this Agreement. 
 “Facility Office” means the office notified by the Lender to the Borrower as being the office or offices through which it will perform
its obligations under this Agreement. 
 “Final Nova Payment” means the payment due from the Borrower to Nova CM under the
relevant Construction Contract on or before 31 January 2009. 
 “Finance Documents” means: 
  

	 	(a)	this Agreement; 

  

	 	(b)	the Security Agreements; 

  

	 	(c)	each Utilisation Request (including each annex and/or schedule thereto); and 

  

	 	(d)	each and every other document designated as such by the Lender and the Borrower. 

 “Financial Covenants” means those covenants set out in Clause 24.1. 
 “Financial
Indebtedness” means any indebtedness in respect of: 
  

	 	(a)	moneys borrowed; 

  

	 	(b)	any amount raised by acceptance under any acceptance credit facility or dematerialised equivalent; 

  

	 	(c)	any amount raised pursuant to any note purchase facility or the issue of bonds, notes, debentures, loan stock or any similar instrument; 

  

	 	(d)	the amount of any liability in respect of any lease or hire purchase contract which would, in accordance with US or UK GAAP, whichever is applicable, be treated as a finance or
capital lease; 

  

	 	(e)	receivables sold or discounted (other than any receivables to the extent they are sold on a non-recourse basis); 

  

	 	(f)	any amount raised under any other transaction (including any forward sale or purchase agreement) having the commercial effect of a borrowing; 

  

 6 

	 	(g)	any derivative transaction entered into in connection with protection against or benefit from fluctuation in any rate or price (and, when calculating the value of any derivative
transaction, only the marked to market value shall be taken into account); 

  

	 	(h)	any counter-indemnity obligation in respect of a guarantee, indemnity, bond, standby or documentary letter of credit or any other instrument issued by a bank or financial
institution; and 

  

	 	(i)	the amount of any liability in respect of any guarantee or indemnity for any of the items referred to in paragraphs (a) to (h) above. 

 “Government Entity” means and includes (whether having a distinct legal personality or not): 
  

	 	(a)	any national government, political sub-division thereof, or local jurisdiction therein; and/or 

  

	 	(b)	any board, commission, department, division, organ, instrumentality, court or agency of any entity referred to in (a) above, however constituted. 

 “gross negligence” means, in relation to a Party, any intentional or conscious action or decision of such Party which is taken with
reckless disregard for the consequences of such action or decision. 
 “Group” means SAVVIS, Inc. and its Subsidiaries for
the time being. 
 “Holding Company” means any holding company within the meaning of Section 1159 companies Act 2006.

 “Increased Costs” has the meaning given to it in Clause 17.1.2. 
 “Indicative Repayment Schedule” means the repayment schedule set out in Schedule 5. 
 “Initial Interest Period” means: (i) for the Advances made prior to the Construction Period End Date, the period set out in Clause
9.2.1.1; and (ii) for the Advances made during the Power Loan Construction Period, the period set out in 9.2.1.2. 
 “Insurance
Event” means any loss or damage to Data Centre Assets, whether or not a Total Loss. 
 “Insurances” means:

  

	 	(a)	all those policies and contracts of insurance which the Lender requires to be procured under the terms of this Agreement or the Security Agreements that insure the Data Centre
Assets, or which are now or may at any time be taken out or enforced in respect of the Data Centre Assets; and 

  

	 	(b)	all rights and other assets derived from any such policies or contracts, including any right to a return of premium. 

 “Intercreditor Agreement” means an agreement dated on or about the date hereof between (1) the Lender; (2) Wells Fargo Foothill
Inc. (as agent) for all Senior Lenders and all Bank Product Providers (each as defined therein); and acknowledged by (1) SAVVIS 

  

 7 

 
Communications Corporation; (2) SAVVIS, Inc.; (3) SAVVIS Communications International, Inc.; (4) SAVVIS Federal Systems Inc.; and (5) the
Borrower to regulate, inter alia, their relevant security interests. 
 “Intercompany UK Debt Subordination Agreement” means
an agreement dated on or about the date hereof between (1) the Lender; (2) the Borrower and (3) SAVVIS Communications Corporation, in relation to the subordination of the payment of intercompany debt between SAVVIS Communications
Corporation and the Borrower. 
 “Interest Letter of Credit” shall have the meaning given to it in Clause 25.2. 

“Interest Period” means, in relation to an Advance, each month or part of a month during the Initial Interest Period and, thereafter,
each period determined in accordance with Clause 12.1 and, in relation to an Unpaid Sum, each period determined in accordance with Clause 9.3. 
 “Land” means the leasehold premises on which the Data Centres are situated. 
 “Landlord” means any person who may from time to time have any superior freehold or leasehold interest to the Borrower in the Land. 
 “LC Amount” has the meaning given to it in Clause 25.1.4. 
 “LC Release
Amount” shall have the meaning given to it in Clause 25.4.4. 
 “Lender’s Group” means the Lender and any of
its Subsidiaries from time to time and its Holding Company from time to time and any company which from time to time is a Subsidiary of its Holding Company. 
 “Letter of Credit” means, individually or collectively, the Original Letter of Credit, any Replacement Letter of Credit and the Interest Letter of Credit. 
 “Letter of Credit Bank” means (i) Wells Fargo Bank NA (if at the relevant time it has a Standard & Poor’s long term
credit rating of at least A-) or (ii) any other OECD bank, or a bank Affiliate of Wells Fargo Bank NA, which the Lender may approve in writing, such approval not to be unreasonably withheld if at the relevant time such bank has a
Standard & Poor’s long term credit rating of at least A-. 
 “LIBOR” means in relation to an Advance, a Loan,
an Unpaid Sum or otherwise: 
  

	 	(a)	the applicable Screen Rate; or 

  

	 	(b)	if the applicable Screen Rate is not available, the arithmetic mean (rounded upwards to four decimal places) of the rates quoted by the Reference Banks to leading banks in the
London interbank market as supplied to the Lender at its request, 

 in each case as of 11:00 AM on the Quotation Day for the
offering of deposits in the currency of that Advance, Loan or Unpaid Sum and for a period comparable to the period in respect of which LIBOR is to be determined. 
 “Loans” means the Commercial Loan or the Power Loan (as the context may require) and, in the plural, will mean both of them or, prior to the Construction Period End Date or the Power Loan Construction
Period End Date, the aggregate of the Advances made under this Agreement. 
  

 8 

 “Losses” means any losses, liabilities, actions claims, proceedings, judgements,
penalties, fines, damage, fees, costs, expenses and Taxes (regardless of when the same are incurred). 
 “Major Claim” means
any claim or claims against the Borrower or SAVVIS, Inc. in respect of which the aggregate amount sought against the Borrower or SAVVIS, Inc. and/or any and all insurers (before adjustment for any relevant franchise or deductible) exceeds
£250,000.00. 
 “Management Report” means an unaudited management report to be provided in accordance with Clause
23.2.5 which addresses the matters set out in Schedule 6 (Contents of Management Report). 
 “Mandatory Cost” means the
percentage rate per annum calculated by the Lender in accordance with Schedule 4. 
 “Margin” means 2.8 per cent. per
annum. 
 “Market Disruption Event” has the meaning given to it in Clause 14.2. 
 “Material Adverse Effect” means any event or circumstance which materially and adversely affects: 
  

	 	(a)	the business condition (financial or otherwise), assets, and operations of the Borrower or SAVVIS, Inc.; or 

  

	 	(b)	the ability of the Borrower or SAVVIS, Inc. to observe or perform any of its obligations under the Finance Documents taking into account, amongst other things, the resources
immediately available to the Borrower and SAVVIS, Inc. without breaching the terms of the Finance Documents; or 

  

	 	(c)	the legality, validity or enforceability of any Finance Document. 

 “Milestone” means each of the milestones for completion of certain works as specified in the Works Schedule. 
 “Month” or “month” means a period starting on one day in a calendar month and ending on the numerically corresponding day in the next calendar month, except that: 
  

	 	(a)	(subject to paragraph (c) below) if the numerically corresponding day is not a Business Day, that period shall end on the next Business Day in that calendar month in which that
period is to end if there is one, or if there is not, on the immediately preceding Business Day; 

  

	 	(b)	if there is no numerically corresponding day in the calendar month in which that period is to end, that period shall end on the last Business Day in that calendar month; and

  

	 	(c)	if an Interest Period begins on the last Business Day of a calendar month, that Interest Period shall end on the last Business Day in the calendar month in which that Interest
Period is to end. 

 The above rules will only apply to the last Month of any period. 
  

 9 

 “Nova CM” means Nova CM Limited,
company number, 4324535 whose registered office is c/o Wilmer, Cutler, Pickering, Hale & Dorr LLP, 5th Floor Alder Castle, 10 Noble Street,
London EC2V 7QJ. 
 “Obligor” means each of the Borrower and SAVVIS, Inc. 
 “Original Financial Statements” means the audited consolidated financial statements for SAVVIS, Inc. prepared in accordance with
US GAAP for the financial year ended on 31 December 2007. 
 “Original Letter of Credit” has the meaning given to
it in Clause 25.1. 
 “Party” means a party to this Agreement and, where the context permits or requires, a party to a
Finance Document. 
 “Permitted Security Interests” means: 
  

	 	(a)	Security Interests created by the Finance Documents; 

  

	 	(b)	Security Interests in favour of Wells Fargo Foothill, Inc. (as lender and as agent as set out in and as defined in the Wells Fargo Facility), and its successors and assigns,
including any lender which refinances or refunds the Wells Fargo Facility and which are subject to the Intercreditor Agreement; 

  

	 	(c)	any netting or set-off arrangement entered into by the Borrower in the ordinary course of its banking arrangements for the purpose of netting debit and credit balances of members of
the Borrower but only so long as such arrangement is not established with the primary intention of preferring any lenders; 

  

	 	(d)	any Security arising under any finance lease retention of title, hire purchase or conditional sale arrangement or arrangements having similar effect in respect of goods supplied to
the Borrower in the ordinary course of business and, unless disputed in good faith, not arising as a result of any default or omission by the Borrower that is continuing for a period of more than 60 days; 

  

	 	(e)	any Security over any rental deposits in respect of any property leased or licensed by the Borrower in respect of amounts representing not more than 12 months’ rent for that
property; 

  

	 	(f)	any Security over documents of title and goods as part of a documentary credit transaction; 

  

	 	(g)	any lien arising by operation of law or otherwise in the ordinary course of business or the construction, operation, repair or maintenance of the Data Centres, provided such liens
do not secure amounts more than 60 days overdue (unless the overdue amount is being contested by the Borrower in good faith by appropriate steps or unless the Borrower obtains written consent of such overdue lien); 

  

	 	(h)	any Security Interest created in favour of a plaintiff or defendant in any proceedings or arbitration as security for costs and expenses where the Borrower is actively prosecuting
or defending such proceedings or arbitration in good faith; or 

  

 10 

	 	(i)	Security Interests arising by operation of law in respect of taxes which are not overdue for payment or which are being contested in good faith by appropriate steps and in respect
of which appropriate reserves have been made, 

 and, save as set out in (a), (b), (g) and (i) above, is not in
respect of any of the Security Assets. 
 “Planning Acts” means the Town and Country Planning Act 1990, the Planning (Listed
Buildings and Conservation Areas) Act 1990, the Planning (Hazardous Substances) Act 1990, the Planning (Consequential Provisions) Act 1990 and any regulations issued or granted under or by virtue of such Acts. 
 “Potential Event of Default” means any event or circumstance specified in Clause 30 which would (with the expiry of a grace period,
the giving of notice, the making of any determination under the Finance Documents or any combination of any of the foregoing) be an Event of Default. 
 “Power Loan” means the aggregate of the Advances made in accordance with Clause 5.1 to finance the payment of, inter alia, certain amounts due from the Borrower to Slough Heat & Power
and the Final Nova Payment. 
 “Power Loan Construction Period” means the period from the Construction Period End Date until
Power Loan Construction Period End Date. 
 “Power Loan Construction Period End Date” means the earlier of: 
 (i) the date of which the Borrower has made all the payments to Slough Heat & Power in respect of the Slough Data Centre and the Final Nova
Payment; and 
 (ii) the last day of the Availability Period. 
 “Power Loan Period” means the period from the Power Loan Construction Period End Date until the end of the Commercial Loan Period. 
 “Power Loan Swap Rate” has the meaning given to it in Clause 11.1 
 “Property All Risk Insurance” means an obligatory insurance as set out in Clause 25. 
 “Property Lease” means any lease to the Borrower of the Land on which the Data Centres are situated. 
 “Quarter End Date” means each of 31 March, 30 June, 30 September, 31 December and 31 March for each year.

 “Quarter” means the period starting on the day after a Quarter End Date and ending on the next Quarter End Date.

 “Quotation Day” means, in relation to any period for which an interest rate is to be determined, the first day of that
period, unless market practice differs in the Relevant Interbank Market, in which case the Quotation Day for that currency will be determined by the Lender in accordance with market practice in the Relevant Interbank Market (and if quotations would
normally be given by leading banks in the Relevant Interbank Market on more than one day, the Quotation Day will be the last of those days). 
  

 11 

 “Reference Banks” means (in relation to LIBOR and Mandatory Cost) the principal London
offices of The Royal Bank of Scotland Plc, Barclays Bank plc, HSBC Bank plc and Lloyds TSB Bank plc or such other banks as may be appointed by the Lender in consultation with the Borrower. 
 “Relevant Interbank Market” means the London interbank market. 
 “Relevant Period” has the meaning given to it in Clause 23.2.5. 
 “Repayment Dates” means the date which falls on the last Business Day of the month which is three (3) months after the Construction
Period End Date and the last Business Day of each successive three month period thereafter. 
 “Repayment Instalment” means
the amount payable by the Borrower on each Repayment Date. 
 “Repayment Schedule” means any schedule provided by the Lender
to the Borrower in accordance with Clauses 10 or 11 detailing the date and amounts for repayment of the Loans. 
 “Repeating
Representations” means each of the representations set out in Clauses 22.2, 22.4, 22.5.1 (but only for the purposes of the first Utilisation Date), 22.6, 22.7, 22.8, 22.9, 22.14, 22.15, 22.16, 22.17, 22.20, 22.21, 22.22, 22.23, 22.25,
22.27.3 and 22.27.4 and each and every representation (with respect to the Borrower) in any other Finance Document which is expressed to be repeated. 
 “Replacement Letter of Credit” has the meaning given to it in Clause 25.4.1. 
 “Replacement Repayment Schedule” means the repayment schedule calculated by the Lender pursuant to and in accordance with the provisions of Schedule 5 or Clause 8.6 or 17.2.3 relating to the repayment of the Commercial Loan
and any Power Loan. 
 “Screen Rate” means the British Bankers’ Association Interest Settlement Rate for the relevant
currency displayed on the appropriate page of the Reuters screen or if there is no such rate displayed on such screen then such rate as displayed on the relevant page of the Telerate screen. 
 “SDLT” mean stamp duty land tax. 
 “Secured Liabilities” means all present and future obligations and liabilities, actual or contingent, of the Borrower or SAVVIS, Inc. to the Lender under or in connection with the Finance Documents or any of them.

 “Security” means the security from time to time constituted by, or pursuant to, the Security Agreements. 
 “Security Agreement” means any of: 
  

	 	(a)	the Asset Security Agreement; 

  

	 	(b)	the Letters of Credit; 

  

	 	(c)	the Intercreditor Agreement; and 

  

 12 

	 	(d)	the Intercompany UK Debt Subordination Agreement. 

 “Security Assets” shall have the meaning given to it in the Security Agreements. 
 “Security
Interest” means any mortgage, pledge, lien, charge, assignment, hypothecation or security interest or any other agreement or arrangement having the effect of conferring security. 
 “Security Period” means the period beginning on the date of this Agreement and ending on the date on which the Lender is satisfied that
all the Secured Liabilities have been unconditionally and irrevocably paid and discharged in full. 
 “Slough Data Centre”
means the Borrower’s Data Centre situated at 630 Ajax Road, Slough, which at the date of this Agreement is under construction. 
 “Slough Heat & Power” means Slough Heat & Power Limited of 5 Vastern Road, Reading, Berkshire, RG1 8BU. 
 “Specified Time” means 11.00a.m. 
 “Sterling” and
“£” means the lawful currency for the time being of the United Kingdom. 
 “Subsidiary” means: 
  

	 	(a)	a subsidiary within the meaning of section 1159 of the Companies Act 2006; and 

  

	 	(b)	in relation to consolidated financial statements of the Borrower, a subsidiary undertaking within the meaning of section 1162 of the Companies Act 2006. 

 “Tax” means any tax, levy, impost, duty or other charge or withholding of a similar nature (including any penalty or interest payable in
connection with any failure to pay or any delay in paying any of the same). 
 “Taxes Act” has the meaning given to it in
Clause 16.1. 
 “Tax Credit” has the meaning given to it in Clause 16.1. 
 “Tax Deduction” means a withholding or deduction for or on account of Tax from a payment under a Finance Document. 
 “Technical Adviser” means PTS Consulting Limited or such other person as the Lender may appoint from time to time to perform such role.

 “Termination Date” means the last Repayment Date for all the Loans. 
 “Total Commitment” means £35,000,000 at the date of this Agreement. 
 “Total Loss” means the actual constructive, compromised or agreed total loss of a Data Centre Asset or Data Centre Assets, which either
singularly or in aggregate have a value in excess of £250,000 immediately prior to the Total Loss Date. 
 “Total Loss Date”
means: 
  

	 	(a)	in the case of an actual loss or construction loss, the date on which that loss occurred; and 

  

 13 

	 	(b)	in the case of a compromised, agreed or arranged Total Loss, the date on which the compromise, agreement or arrangement is made by or on behalf of the Borrower or SAVVIS, Inc. with
the insurers. 

 “UK GAAP” means the generally accepted accounting principles in the United Kingdom of the
Borrower. 
 “Unpaid Sum” means any sum payable but unpaid by any Obligor under the Finance Documents. 
 “US Dollar” and “$” means the lawful currency for the time being of the United States of America. 
 “US GAAP” means generally accepted accounting principles as in effect from time to time in the United States, consistently
applied. 
 “Utilisation” means a utilisation of the Facility. 
 “Utilisation Date” means the date of a Utilisation, being the date on which the relevant Advance (or Advances) is (or are) to be made.

 “Utilisation Request” means a notice substantially in the form set out in Schedule 3. 
 “VAT” means value added tax as provided for in the Value Added Tax Act 1994 and any other tax of a similar nature. 
 “Wells Fargo Facility” means a revolving credit facility dated 10 June 2005 provided by Wells Fargo Bank NA to SAVVIS Communications
Corporation evidenced by a credit agreement dated 10 June 2005, by and among SAVVIS Communications Corporation (as borrower), SAVVIS, Inc. (as guarantor), Wells Fargo Foothill Inc., as a lender and as agent as set out in and as defined in the
credit agreement and any amendment or replacement thereof. 
 “Winding Up” means any winding up, amalgamation,
reconstruction, administration, receivership, dissolution, liquidation, merger or consolidation or any analogous procedure or step in any jurisdiction. 
 “Winnersh Data Centre” means the Borrower’s Data Centre at Eskdale Road, Winnersh Triangle, Wokingham, Berkshire RG41 5GS. 
 “Works Schedule” means in respect of the Slough Data Centre the schedule of works as approved by the Lender and as set out in Schedule 7
hereto, as may be amended, varied, modified, updated or revised from time to time in accordance with Clause 23.4.3. 
  

	1.2	Construction 

  

	1.2.1	Unless a contrary indication appears, any reference in this Agreement to: 

  

	 	1.2.1.1	the “Lender”, the “Borrower”, the “Guarantor”, any “Obligor” or any “Party” shall be construed
so as to include its successors in title, permitted assigns and permitted transferees; 

  

 14 

	 	1.2.1.2	“assets” includes present and future properties, revenues and rights of every description; 

  

	 	1.2.1.3	“contingent liability” means a liability which is not certain to arise and/or the amount of which remains unascertained; 

  

	 	1.2.1.4	“document” includes a deed and also a letter, fax or telex; 

  

	 	1.2.1.5	“expense” means any kind of cost, charge or expense (including all legal costs, charges and expenses) and any applicable Tax including VAT;

  

	 	1.2.1.6	a “Finance Document” or any other agreement or instrument is a reference to that Finance Document or other agreement or instrument as amended or novated;

  

	 	1.2.1.7	“indebtedness” includes any obligation (whether incurred as principal or as surety) for the payment or repayment of money, whether present or future, actual or
contingent; 

  

	 	1.2.1.8	“law” includes any order or decree, any form of delegated legislation, any treaty or international convention and any regulation or resolution of the Council of the
European Union, the European Commission, the United Nations or its Security Council. 

  

	 	1.2.1.9	“proceedings” means, in relation to any enforcement provision of a Finance Document, proceedings of any kind, including an application for a provisional or
protective measure; 

  

	 	1.2.1.10	a “person” includes any person, firm, company, corporation, government, state or agency of a state or any association, trust or partnership (whether or not having
separate legal personality) or two or more of the foregoing; 

  

	 	1.2.1.11	a “regulation” includes any regulation, rule, official directive, request or guideline (whether or not having the force of law) of any governmental,
intergovernmental or supranational body, agency, department or regulatory, self-regulatory or other authority or organisation; 

  

	 	1.2.1.12	a provision of law is a reference to that provision as amended or re-enacted; 

  

	 	1.2.1.13	a time of day is a reference to London time; 

  

	 	1.2.1.14	any English legal term for any action, remedy, method of judicial proceeding, legal document, legal status, court, official or any legal concept or thing shall, in respect of a
jurisdiction other than England, be deemed to include the Lender which most nearly approximates in that jurisdiction to the English legal term; 

  

	 	1.2.1.15	any defined term or noun in the plural number or collective plural or in the singular number shall be interpreted with such changes as may be necessary to include the singular or
the plural number or collective plural and to each and every part of such plural number or collective plural; and 

  

 15 

	 	1.2.1.16	“including” and “in particular” (and other cognate references) shall be construed as not limiting any general words or expressions in connection
with which they are used. 

  

	1.2.2	Section, Clause and Schedule headings are for ease of reference only. 

  

	1.2.3	Unless a contrary indication appears, a term used in any other Finance Document or in any notice given under or in connection with any Finance Document has the same meaning in that
Finance Document or notice as in this Agreement. 

  

	1.2.4	A Potential Event of Default is “continuing” if it has not been remedied or waived and an Event of Default is “continuing” if it has not been
waived or remedied. 

  

	1.3	Construction of insurance provisions 

 In this
Agreement: 
 “approved” means, for the purposes of Clause 25, approved in writing by the Lender.

 “obligatory insurances” means, in relation to any Data Centre or the Borrower’s business, all Insurances effected, or
which the Borrower is obliged to effect, under Clause 29 or any other provision of this Agreement or of another Finance Document. 
 “policy” in relation to any insurance, includes any document evidencing the contract of insurance or its terms. 
  

	1.4	Third party rights 

  

	1.4.1	Unless expressly provided to the contrary in a Finance Document, a person who is not a Party has no right under the Contracts (Rights of Third Parties) Act 1999 (the “Third
Parties Act”) to enforce or to enjoy the benefit of any term of this Agreement. 

  

	1.4.2	Notwithstanding any term of any Finance Document, the consent of any person who is not a Party is not required to rescind or vary this Agreement at any time.

  

	1.5	Settlement or discharge conditional 

 Any settlement
or discharge under any Finance Document between the Lender and the Borrower shall be conditional upon no security or payment to the Lender by the Borrower or any other person being set aside, adjusted or ordered to be repaid, whether under any
insolvency law or otherwise. 
  

	1.6	Irrevocable payment 

 If the Lender considers an
amount paid or discharged by, or on behalf of, the Borrower or by any other person in purported payment or discharge of an obligation of the Borrower to the Lender under the Finance Documents is capable of being avoided or otherwise set aside on the
liquidation or administration of the Borrower or otherwise, then that amount shall not be considered to have been unconditionally and irrevocably paid or discharged for the purposes of the Finance Documents. 
  

 16 

 SECTION 2 
 THE FACILITIES 
  

	2	THE FACILITY 

 Subject to the terms of this
Agreement, the Lender shall make available to the Borrower a term loan facility in an aggregate amount equal to £35,000,000. 
  

	3	PURPOSE 

  

	3.1	Purpose 

  

	3.1.1	The Borrower shall apply all amounts borrowed by it under the Facility in connection with the acquisition, design, construction, installation and fit out of the Slough Data Centre,
all other work necessary in order to render the Slough Data Centre fully operational in accordance with the Works Schedule and all fees, costs and expenses incurred by it in connection with the Finance Documents. 

  

	3.2	Monitoring 

 The Lender is not bound to monitor or
verify the application of any amount borrowed pursuant to this Agreement. 
  

	4	CONDITIONS OF UTILISATION 

  

	4.1	Initial conditions precedent 

 The Lender shall not
have any obligation hereunder nor shall the Borrower deliver any Utilisation Request in respect of the Facility unless the Lender has received all of the documents and other evidence listed in Part I of Schedule 2 in form and substance satisfactory
to the Lender prior to the delivery of the initial Utilisation Request. 
  

	4.2	Further conditions precedent 

 The Lender will only
be obliged to comply with Clause 6.4 if on the date of a Utilisation Request and on a proposed Utilisation Date: 
  

	 	4.2.1.1	no Default has occurred and is continuing or would result from the proposed Advance; 

  

	 	4.2.1.2	the Repeating Representations to be made by the Borrower are true in all material respects; 

  

	 	4.2.1.3	the Lender has received all of the documents and other evidence listed in Part II of Schedule 2 and Clause 5 (where relevant), in form and substance satisfactory to the Lender prior
to the delivery of the relevant Utilisation Request. 

  

	4.2.2	Notification of satisfaction of conditions precedent 

 The Lender shall notify the Borrower promptly upon being satisfied as to the satisfaction of the conditions precedent referred to in Clauses 4.1, 4.2 and 5. 
  

 17 

	4.2.3	Waiver of conditions precedent 

  

	 	4.2.3.1	If the Lender, at its discretion, permits an Advance to be borrowed before all or some of the conditions precedent referred to in Clauses 4.1, 4.2 and 5 have been satisfied, the
Borrower shall ensure that those conditions are satisfied within 5 (five) Business Days after the Utilisation Date or such other date as the Lender, acting reasonably, may agree in writing with the Borrower. 

  

	 	4.2.3.2	The Lender agrees that it will waive the condition precedent referred to in paragraph 2.4 of Part 1 of Schedule 2 subject to the following terms: 

  

	 	(i)	the Borrower shall procure delivery of the Interest Letter of Credit within fourteen (14) days of the date hereof; and 

  

	 	(ii)	the first drawdown shall be for the amount set out in the relevant Utilisation Request, less the amount of £242,083.33 which shall be retained by the Lender and only paid to
the Borrower upon satisfaction of the Borrower’s obligation in paragraph (i) above. 

  

	5	UTILISATION OF POWER LOANS 

  

	5.1	During the Power Loan Construction Period, subject always to Clauses 4.1, 4.2 and 6, the Borrower may request further Advances from the Lender in order to finance the payment of
certain amounts due from the Borrower to Slough Heat & Power and the Final Nova Payment. In addition to the further conditions precedent specified in Clause 4.2, on or prior to delivery of the relevant Utilisation Request, the Borrower must
provide the Lender with copies of invoices from Slough Heat & Power and, where relevant, Nova CM detailing the payments to be made by the Borrower. 

  

 18 

 SECTION 3 
 UTILISATION 
  

	6	UTILISATION 

  

	6.1	Delivery of a Utilisation Request 

  

	6.1.1	Subject to the terms of this Agreement, the Borrower may utilise the Facility by delivery to the Lender during the Availability Period of a duly completed Utilisation Request not
later than the Specified Time. The Borrower may not issue more than one Utilisation Request in every two weeks during the Availability Period. 

  

	6.2	Completion of a Utilisation Request 

  

	6.2.1	Each Utilisation Request is irrevocable and will not be regarded as having been duly completed unless: 

  

	 	6.2.1.1	the currency and the amount of the Utilisation comply with Clause 6.3 (Currency and Amount); and 

  

	 	6.2.1.2	it complies with Clause 6.2.2 

  

	6.2.2	The Borrower may request only one Advance in each Utilisation Request and shall confirm in any such Utilisation Request that it has paid all VAT on any payment referred to in
6.3.2.2. 

  

	6.3	Currency and amount 

  

	6.3.1	The currency specified in a Utilisation Request must be Sterling. 

  

	6.3.2	The amount of the proposed Loan must be an amount which is: 

  

	 	6.3.2.1	at least £500,000 or, if less, the Available Commitment; and 

  

	 	6.3.2.2	not more than the amount due and payable at that time to either: (i) the Contractor(s) under the terms of the Construction Contracts, upon completion of the relevant Milestones
at that date as set out in Schedule 7 and as certified to the Lender in writing (in such form as the Lender may reasonably require) by the Technical Adviser; or (ii) Slough Heat & Power; or (iii) Nova CM for the Final Nova
Payment. 

  

	6.3.3	In any event, the amount of the proposed Advance in a Utilisation Request relating to the Facility must be an amount which when aggregated with the other Advance(s) (if any)
requested under other Utilisation Requests is not more than the Available Commitment. 

  

	6.4	Disbursement of the Loan 

  

	6.4.1	If the conditions set out in this Agreement have been met, the Lender shall make each Advance available by the Utilisation Date through its Facility Office.

  

	6.4.2	The Borrower shall pay to the Lender the Arrangement Fee and all costs and expenses referred to in Clause 20.1.1 out of the proceeds of the First Advance and, in discharge of such
obligations, the Lender shall retain out of such proceeds an amount equal to such Arrangement Fee and costs and expenses. 

  

 19 

 SECTION 4 
 REPAYMENT, CANCELLATION AND EARLY CANCELLATION 
  

	7	REPAYMENT 

  

	7.1	Repayment of the Loans 

  

	7.1.1	The Borrower shall repay the Loan or Loans on the dates, and in the amounts, set out in the Repayment Schedules to be provided by the Lender to the Borrower in accordance with
Clauses 10 and 11 or any Replacement Repayment Schedule provided in accordance with Schedule 5 or Clauses 8.6, 10 or 11. 

  

	7.1.2	An Indicative Repayment Schedule is set out Schedule 5. 

  

	7.2	Re-borrowing 

 The Borrower may not re-borrow any
part of the Facility which is repaid. 
  

	8	PREPAYMENT, CANCELLATION AND EARLY TERMINATION 

  

	8.1	Automatic cancellation of Facility 

 The unutilised
Total Commitment shall be automatically cancelled at close of business on the last day of the Availability Period. 
  

	8.2	Mandatory automatic prepayment 

  

	 	8.2.1.1	Sale of Assets 

 If any of the Class A Data Centre
Assets are sold in accordance with the terms of the Asset Security Agreement (and the Lender has not directed that such sales proceeds shall be used by the Borrower to acquire replacement Data Centre Assets) the Borrower shall prepay an amount of
the Commercial Loan (and, thereafter (if the Commercial Loan has been paid in full) the Power Loan) together with any Break Costs (minus any Break Gains) which equals the amount of sales proceeds received by the Borrower, immediately upon receipt of
such sales proceeds by the Borrower (and until such sales proceeds are paid by the Borrower to the Lender, they shall be held on trust by the Borrower for the Lender) in respect of such sale. 
  

	 	8.2.1.2	Application of Insurance Proceeds 

  

	 	(a)	For the purpose of this Clause the percentage calculations set out in sub-Clauses (b) and (c) below shall be calculated by having regard to the aggregate value of the Data
Centre Assets which are the subject of an Insurance Event as at the day before such Insurance Event occurred and the aggregate value of all of the Data Centre Assets at the Affected Data Centre (as defined in Clause 8.2.1.2(c) below) as at the day
before such Insurance Event occurred. 

  

 20 

	 	(b)	If an Insurance Event occurs to 60% (sixty per cent) or less in value of the Data Centre Assets at any Data Centre then, subject to no Event of Default having occurred and being
continuing at the date of the Insurance Event, any insurance proceeds received shall, unless the Borrower elects to make a prepayment of the Loan or Loans in accordance with Clause 8.3, be applied within five (5) Business Days of receipt, in
accordance with Clause 29.5.1. 

  

	 	(c)	If an Insurance Event occurs to more than 60% (sixty per cent) in value of the Data Centre Assets at any Data Centre (the “Affected Data Centre Assets”), then
within thirty (30) days of the occurrence of the Insurance Event, the Borrower shall notify the Lender in writing as to whether the Borrower intends to use any insurance proceeds received: (i) to repair or replace the Affected Data Centre
Assets; or (ii) to make a prepayment of the Loan or Loans (together with the payment of any Break Costs (less Break Gains)). Without prejudice to the Borrower’s obligation to continue paying Repayment Instalments to the Lender as and when
they fall due: 

  

	 	(i)	If the insurance proceeds are received in full within 180 (one hundred and eighty) days of the date of the Borrower’s notice referred to above, then such insurance proceeds
shall be applied by the Borrower as set out in its notice. 

  

	 	(ii)	If the insurance proceeds are not received in full within 180 (one hundred and eighty) days of the date of the Borrower’s notice referred to above, then the Lender and the
Borrower shall enter into good faith negotiations for a maximum period of 30 (thirty) days to decide whether or not the Borrower must either: 

  

	 	(aa)	immediately pre-pay the Loan or Loans in an amount equal to the value of the Affected Data Centre Assets as at the day before the Insurance Event occurred; or

  

	 	(bb)	provide alternative security of a type and on terms satisfactory to the Lender (the Lender’s agreement to such security not to be unreasonably withheld or delayed).

 Sub-clause (aa) and (bb) above are without prejudice to the right of the parties to reach any other solution within the
thirty day negotiation period which they both agree to be suitable. 
 Once agreement is reached, the Borrower shall comply with that
agreement within the time frame agreed. 
  

	 	(d)	If the Borrower makes a pre-payment of the Loan or Loans in accordance with Clause (c)(ii) above, any insurance proceeds received by the Lender in respect of the Affected Data
Centre Assets after the date of pre-payment shall, in the event that no Event of Default has occurred and is continuing at the time of receipt, be paid by the Lender to the Borrower within 5 (five) Business Days of receipt, or if an Event of Default
has so occurred and is continuing, be retained by the Lender and applied by the Lender in repayment of any sums then due from the Borrower and thereafter the Lender shall refund to the Borrower the insurance proceeds, if any, received by the Lender
in excess of the amount then due from the Borrower. 

  

 21 

	 	(e)	The parties agree that, provided that no Event of Default has occurred and is continuing at the time of receipt of any insurance proceeds, any insurance proceeds received (whether
in the form of a cheque or otherwise) shall be paid into a bank account at such bank as the Lender may require and in respect of which both the Lender and the Borrower are authorised signatories. Subject to clause 8.2.1.2 (f), no insurance proceeds
may be withdrawn from such account until the earlier of the date that the Borrower is required to either (i) pay any supplier who is supplying the relevant replacement Data Centre Assets; or (ii) make a pre-payment of the Loan or Loans
under this Agreement. 

  

	 	(f)	Following the occurrence of an Event of Default which, if capable of being remedied, is not remedied within any grace period set out in this Agreement, any insurance proceeds shall
be applied by the Lender in repayment of the Loan or Loans and the Borrower and SAVVIS, Inc. agree that they shall do all matters, acts and things that the Lender may reasonably require to procure that any insurance proceeds are be paid to the
Lender to such account as the Lender may require. 

  

	8.3	Early Termination by Borrower 

  

	8.3.1	Subject to Clause 8.3.2, the Borrower may at any time, so long as no Event of Default has occurred or is continuing at that time, if it gives the Lender not less than 10 Business
Days’ prior written notice, elect to terminate the Facility (or part thereof as identified in such notice) on a Repayment Date identified in such notice and prepay on the Early Termination Date the whole or such part of the Loans as well as any
Break Costs (minus any Break Gains) (as calculated on the Early Termination Date) and any other amounts outstanding under the Finance Documents. Except as expressly set out in this Clause 8.3.1, no premium or penalty shall be payable in respect of
any termination pursuant to this Clause 8.3.1. 

  

	8.3.2	Any partial termination and pre-payment under Clause 8.3.1 must be in an amount of at least £1,000,000 (one million pounds Sterling). 

  

	8.4	Illegality 

  

	8.4.1	If it becomes (or will become) unlawful in any jurisdiction or under Applicable Law(s) for the Lender to perform any of its obligations as contemplated by any Finance Document(s),
the Lender shall promptly notify the Borrower thereof. 

  

	8.4.2	Upon the Lender notifying the Borrower pursuant to Clause 8.4.1 the Available Commitment will be immediately cancelled. 

  

	8.4.3	After the Lender notifies the Borrower pursuant to Clause 8.4.1 the Borrower shall repay the Lender the Loans, together with the Lender’s Break Costs (minus any Break Gains)
(as calculated with effect from that day) and any other outstanding amounts due to the Lender at that time, on the last day of the Interest Period occurring after receipt by the Borrower of such notice or, if earlier, the date specified by the
Lender in the notice (being no earlier than the last day of any applicable grace period permitted by law). 

  

	8.4.4	Any prepayment pursuant to the foregoing provisions of this Clause 8.4 shall be made in accordance with, and subject to, the relevant other provisions of this Clause 8.

  

 22 

	8.5	Restrictions 

  

	8.5.1	Any notice of cancellation or prepayment given by any Party under this Clause 8 shall be irrevocable and, unless a contrary indication appears in this Agreement, shall specify
the date or dates upon which the relevant cancellation or prepayment is to be made. 

  

	8.5.2	Any prepayment under this Agreement shall be made together with accrued interest on the amount prepaid, and any Break Costs (minus any Break Gains), without premium or penalty.

  

	8.5.3	The Borrower may not re-borrow any part of the Facility which is prepaid. 

  

	8.5.4	The Borrower shall not repay or prepay all or any part of the Loan or cancel all or any part of the Available Commitment except at the times and in the manner expressly provided for
in this Agreement. 

  

	8.5.5	No amount of the Total Commitments cancelled under this Agreement may be subsequently reinstated. 

  

	8.6	Replacement Repayment Schedule 

  

	8.6.1	No later than five (5) Business Days prior to the Construction Period End Date (in respect of the Commercial Loan) and the Power Loan Construction Period End Date (in respect
of the Power Loan) the Lender shall provide the Borrower with a Replacement Repayment Schedule showing the actual Repayment Dates and the amount of principal of the Commercial Loan or Power Loan (as appropriate) payable on each Repayment Date
together with, if the Borrower has made an election in accordance with Clause 9.4.5, the amount of interest payable by the Borrower on each Repayment Date. 

  

	8.6.2	Following a partial prepayment of the Loan or Loans pursuant to or in accordance with this Clause 8, the Lender shall, applying methodology consistent with that in relation to the
preparation of the Repayment Schedule, calculate a Replacement Repayment Schedule or Replacement Repayment Schedules (as appropriate) relating to the Loans and, in the absence of any manifest error, such Replacement Repayment Schedule or Replacement
Repayment Schedules shall be and shall constitute the Repayment Schedule for the Loans thereafter. 

  

 23 

 SECTION 5 
 COSTS OF UTILISATION 
  

	9	INTEREST 

  

	9.1	Calculation of interest 

  

	9.1.1	The rate of interest for each Advance during the Construction Period or the Power Loan Construction Period is the percentage rate per annum which is the aggregate of:

  

	 	9.1.1.1	monthly LIBOR plus Margin; and 

  

	 	9.1.1.2	Mandatory Cost, if any. 

  

	9.1.2	The rate of interest for each Interest Period during the Commercial Loan Period or the Power Loan Period is the percentage rate per annum which is the aggregate of the applicable:

  

	 	9.1.2.1	Margin; 

  

	 	9.1.2.2	the Commercial Loan Period Swap Rate or the Power Loan Period Swap Rate (as applicable) if the Borrower makes an election in accordance with Clause 9.4.5, or monthly LIBOR or
three-month LIBOR as the Borrower may elect in accordance with Clause 9.4.4; and 

  

	 	9.1.2.3	Mandatory Cost, if any. 

  

	9.2	Payment of interest 

  

	9.2.1	The Borrower shall pay accrued interest on the Loan or Loans: 

  

	 	9.2.1.1	in respect of any Advance made prior to the Construction Period End Date, on the last day of the period from the date of Utilisation of such Advance until the earlier of:
(i) the Construction Period End Date; and (ii) the date the Loan is terminated or pre-paid in accordance with this Agreement; and 

  

	 	9.2.1.2	in respect of any Advance made during the Power Loan Construction Period, on the last day of the period from the date of Utilisation of such Advance until the earlier of:
(i) the Power Loan Construction Period End Date; and (ii) the date the Loan is terminated or pre-paid in accordance with this Agreement; and 

  

	 	9.2.1.3	thereafter on the last day of each Interest Period during the Commercial Loan Period or the Power Loan Period (as applicable). 

  

	9.3	Default interest 

  

	9.3.1	If the Borrower fails to pay any amount payable by it under a Finance Document on its due date, interest shall accrue on the Unpaid Sum from the due date up to the date of actual
payment (both before and after judgment) on such Unpaid Sum at the rate which is 2% per annum above the rate calculated in accordance with Clause 9.1. Any interest accruing under this Clause 9.3 shall be immediately payable by the Borrower
on demand by the Lender. 

  

 24 

	9.3.2	Default interest (if unpaid) arising on any Unpaid Sum will be compounded with the Unpaid Sum at the end of each interest period applicable to that Unpaid Sum but will remain
immediately payable. 

  

	9.4	Notification of rates of interest 

  

	9.4.1	Not later than five (5) Business Days before the commencement of the Initial Interest Period relating to any Advance and, thereafter, five Business Days before the commencement
of each calendar month during such Initial Interest Period, the Lender shall, by way of reference only, notify the Borrower of the rate of monthly LIBOR as at such date of notification. Not later than three (3) Business Days after the
commencement of each Initial Interest Period and, thereafter, five Business Days after the commencement of each calendar month during such Initial Interest Period, the Lender shall notify the Borrower of the actual rate of monthly LIBOR as at the
date of commencement of such Initial Interest Period and the commencement of each calendar month during each such Initial Interest Period and which shall be the rate of LIBOR applying under Clause 9.1.1.1. 

  

	9.4.2	Not later than five (5) Business Days before the commencement of each calendar month during each Interest Period during the Commercial Loan Period and the Power Loan Period or,
where the Borrower has elected that three-month LIBOR shall apply in accordance with Clause 9.4.4, not later than five (5) Business Days before the commencement of each Interest Period during the Commercial Loan Period and the Power Loan
Period, the Lender shall, by way of reference only, notify the Borrower of the rate of monthly LIBOR or three-month LIBOR (as applicable) as at such date of notification. Not later than three (3) Business Days after the commencement of each
calendar month during each Interest Period during the Commercial Loan Period and the Power Loan Period or, where the Borrower has elected that three-month LIBOR shall apply in accordance with Clause 9.4.4, not later than three (3) Business Days
after the commencement of each Interest Period during the Commercial Loan Period and the Power Loan Period, the Lender shall notify the Borrower of the actual rate of monthly LIBOR or three-month LIBOR (as applicable) as at the commencement of each
such calendar month or Interest Period and which shall be the LIBOR rate applying under Clause 9.1.2.2 for such calendar month or Interest Period. 

  

	9.4.3	The Lender shall, if the Borrower makes the election pursuant to Clause 9.4.5, notify the Borrower of the Commercial Loan Period Swap Rate in accordance with Clause 10 below and
each Power Loan Period Swap Rate in accordance with Clause 11 below. 

  

	9.4.4	The Borrower may elect by written notice to the Lender, received by the Lender not later than ten (10) Business Days prior to either: 

  

	 	(i)	the Construction Period End Date in respect of the Commercial Loan; or 

  

	 	(ii)	the Power Loan Construction Period End Date in respect of the Power Loan, 

 that the rate to be applied in accordance with Clause 9.1.2.2 shall be either monthly LIBOR or three-month LIBOR. This rate shall then apply for the next succeeding twelve (12) months of the Commercial Loan
Period or the Power Loan Period (as applicable), unless the Borrower makes an election in accordance with Clause 9.4.5. 
  

	9.4.5	 The Borrower may elect by written notice to the Lender, received by the Lender not later than ten (10) Business Days prior to the Construction Period End Date
or not later than ten (10) business Days prior to the last Business Day of any Interest Period thereafter (the Construction Period End Date or the last Business Day of any Interest Period thereafter, to be defined for 

  

 25 

	 	 
these purposes as the “Interest Fix Date”), to fix the funding in relation to all Loans for the period immediately following the Interest
Fix Date, until the date selected by the Borrower under Clause 10.2 or Clause 11.2 (as applicable). If the Lender received such notice, the terms of Clauses 10 and 11 shall apply. 

  

	9.4.6	If the Borrower does not make the election pursuant to Clause 9.4.5, the Lender shall provide the Borrower with Repayment Schedules setting out the Repayment Dates and the Repayment
Instalments for the Commercial Loan Period and the Power Loan Period at least 10 Business Days before the commencement of the next Interest Period. 

  

	10	COMMERCIAL LOAN PERIOD SWAP RATE AND REPAYMENT SCHEDULE 

  

	10.1	The Commercial Loan Period Swap Rate shall be the rate notified by the Lender to the Borrower not later than five (5) Business Days before the Interest Fix Date, being the rate
available as at the Interest Fix Date in the swap market for interest rates for the same currency, term and repayment profile as the Commercial Loan for the Commercial Loan Period. 

  

	10.2	If three-month LIBOR is less than 8% at such time, the Borrower may, subject to Clause 12, not later than 7 (seven) Business Days before the Interest Fix Date, request that the
Commercial Loan Period Swap Rate is that rate available as at the Interest Fix Date in the swap market for interest rates for the same currency and repayment profile as the Commercial Loan, but for a period of three years only or three years and any
increment of 6 (six) months, up to a maximum of 4 (four) years and six months, instead of the Commercial Loan Period. The Lender shall notify the Borrower of such rate at least 5 (five) Business Days before the Interest Fix Date.

  

	10.3	If Clause 10.2 is applied then, no later than ten (10) Business Days prior to the last day of the period selected by the Borrower under Clause 10.2, the Borrower may elect by
written notice to the Lender either: (i) that the rate to be applied for the next succeeding twelve months of the Commercial Loan Period (or shorter period if less than twelve months of the Commercial Loan Period remains) shall be either
monthly LIBOR or three-month LIBOR (and thereafter Clauses 9.4.4 and 9.4.5 shall apply for any further Interest Periods); or (ii) the Borrower may elect to fix the funding in relation to all Loans for the period immediately following the end of
the period selected by the Borrower under Clause 10.2 for the remainder of the Commercial Loan Period and the Lender shall notify the Borrower of the Commercial Loan Period Swap Rate, being the rate available as at the last day of the period
selected by the Borrower under Clause 10.2 in the swap market for interest rates for the same currency, term and repayment profile as the Commercial Loan, for the period from the last day of the period selected by the Borrower under Clause 10.2 to
the end of the Commercial Loan Period and the Lender shall provide the Borrower with a Replacement Repayment Schedule in accordance with Clause 10.4. 

  

	10.4	Within 5 Business Days of the Lender notifying the Borrower of the rate in accordance with Clause 10.1, 10.2 or 10.3, the Lender shall provide the Borrower with a Repayment Schedule
setting out the Repayment Dates and the Repayment Instalments for the Commercial Loan Period or relevant part thereof. For the avoidance of doubt such Repayment Schedule will show both the amount of principal and interest payable on each Repayment
Date and the Repayment Schedule shall provide that the first eight (8) Repayment Instalments for the Commercial Loan Period comprise only of interest accrued on the Commercial Loan. 

  

	11	POWER LOAN PERIOD SWAP RATE AND REPAYMENT SCHEDULE 

  

	11.1	The Power Loan Period Swap Rate shall be the rate notified by the Lender to the Borrower not later than five (5) Business Days before the Interest Fix Date, being the rate
available as at the Interest Fix Date in the swap market for interest rates for the same currency, term and repayment profile as the Power Loan for the Power Loan Period. 

  

 26 

	11.2	If three-month LIBOR is less than 8% at such time, the Borrower may, subject to Clause 12, not later than 7 (seven) Business Days before the Interest Fix Date, request that the
Power Loan Period Swap Rate is that rate available as at the Interest Fix Date in the swap market for interest rates for the same currency and repayment profile as the Power Loan, but for a period of three years only or three years and any increment
of 6 (six) months, up to a maximum of 4 (four) years and six months, instead of the Power Loan Period. The Lender shall notify the Borrower of such rate at least 5 (five) Business Days before the Interest Fix Date. 

  

	11.3	If Clause 11.2 is applied then, no later than ten (10) Business Days prior to the last day of the period selected by the Borrower under Clause 11.2, the Borrower may elect by
written notice to the Lender either: (i) that the rate to be applied for the next succeeding twelve months of the Power Loan Period (or shorter period if less than twelve months of the Power Loan Period remains) shall be either monthly LIBOR or
three-month LIBOR (and thereafter Clauses 9.4.4 and 9.4.5 shall apply for any further Interest Periods); or (ii) the Borrower may elect to fix the funding in relation to all Loans for the period immediately following the end of the period
selected by the Borrower under Clause 11.2 for the remainder of the Power Loan Period and the Lender shall notify the Borrower of the Power Loan Period Swap Rate, being the rate available as at the last day of the period selected by the Borrower
under Clause 11.2 in the swap market for interest rates for the same currency, term and repayment profile as the Power Loan, for the period from the last day of the period selected by the Borrower under Clause 11.2 to the end of the Power Loan
Period and the Lender shall provide the Borrower with a Replacement Repayment Schedule in accordance with Clause 11.4. 

  

	11.4	Within 5 Business Days of the Lender notifying the Borrower of the rate in accordance with Clause 11.2, 11.3 or 11.4, the Lender shall provide the Borrower with a Repayment Schedule
setting out the Repayment Dates and the Repayment Instalments for the Power Loan Period or relevant part thereof. 

  

	11.5	For the avoidance of doubt: 

  

	11.5.1	the Power Loan Period shall be co-terminous with the Commercial Loan Period; 

  

	11.5.2	the Repayments Dates for the Power Loan shall be same as for the Commercial Loan (although the first such Repayment Date for the Power Loan shall be the Repayment Date for the
Commercial Loan falling on or after the Power Loan Construction Period End Date); 

  

	11.5.3	if on any Repayment Date, the Repayment Instalment due from the Borrower on such Repayment Date in respect of the Commercial Loan comprises of interest only (as provided in Clause
10.4), the Repayment Instalment for the Power Loan falling on such Repayment Date shall also comprise of interest only and, if on any Repayment Date, the Repayment Instalment due from the Borrower on such Repayment Date in respect of the Commercial
Loan comprises both principal and interest, the Repayment Instalment for the Power Loan falling on such Repayment Date shall also comprise both principal and interest. 

  

	12	HEDGING 

  

	12.1	 For any period of the Commercial Loan or Power Loan where the rate of interest is not fixed in accordance with Clause 10.2, 10.3, 11.2 or 11.3, if LIBOR equals or
exceeds 8% at any time following the date of the first Advance under this Agreement, then the Borrower shall, within ten (10) Business Days, following demand by the Lender, enter into such interest rate risk 

  

 27 

	 	 
management strategy with RBS FM as the Lender may require for the remainder of the Construction Period and Commercial Loan Period and/or the Power Loan
Construction Period and the Power Loan Period (as appropriate) as the Lender may require. 

  

	12.2	If rate of interest is fixed for any period in accordance with either Clause 10.2, 10.3, 11.2 or 11.3, and at any time during the period which the Borrower has selected and for
which the rate of interest is fixed, LIBOR equals or exceeds 8%, then the Borrower shall, within ten (10) Business Days, following demand by the Lender, enter into such interest rate risk management strategy with RBS FM as the Lender may
require for the remainder of the Commercial Loan Period or the Power Loan Period (as applicable) to which the then current Commercial Loan Swap rate or the Power Loan Period Swap Rate (as applicable) does not apply, as the Lender may require.

  

	13	THE INTEREST PERIOD 

  

	13.1.1	The Initial Interest Period for any Advance made prior to the Construction Period End Date shall be that period specified in Clause 9.2.1.1 and for any Advance made during the Power
Loan Construction Period shall be that period specified in Clause 9.2.1.2 and 

  

	 	13.1.1.1	provided that no Event of Default has occurred and is continuing (in which case Clause 30.21.2 will apply) or none of the events set out in Clause 8 which trigger a prepayment have
occurred, at the Construction Period End Date, all Advances made prior to the Construction Period End Date shall be consolidated at the Construction Period End Date and treated as the Commercial Loan; and 

  

	 	13.1.1.2	provided that no Event of Default has occurred and is continuing (in which case Clause 30.21.2 will apply) or none of the events set out in Clause 8 which trigger a prepayment have
occurred on or before the Power Loan Construction Period End Date, all Advances made during the Power Loan Construction Period shall be consolidated as at 30 June 2009 and treated as the Power Loan. 

  

	13.1.2	During the Initial Interest Period for any Advance, LIBOR shall be calculated on a monthly basis and shall be notified by the Lender to the Borrower in accordance with Clause 9.4.1.

  

	13.1.3	Each Interest Period during the Commercial Loan Period and the Power Loan Period shall be a three month period, the last day of which shall be a Repayment Date.

  

	13.1.4	Interest will accrue daily during the Initial Interest Period and each Interest Period thereafter. 

  

	13.2	Non-Business Days 

 If an Interest Period would
otherwise end on a day which is not a Business Day, the Interest Period will instead end on the next Business Day in that calendar month (if there is one) or the preceding Business Day (if there is not). 
  

	14	CHANGES TO THE CALCULATION OF INTEREST 

  

	14.1	Absence of quotations 

 Subject to Clause 14.2,
if the applicable LIBOR is to be determined by reference to the Reference Banks but a Reference Bank does not supply a quotation by the Specified Time on the Quotation Day, the applicable LIBOR shall be determined on the basis of the quotations of
the remaining Reference Banks. 
  

 28 

	14.2	Market disruption 

 In this Agreement
“Market Disruption Event” means: 
  

	14.2.1	at or about noon on the applicable Quotation Day for each month during the relevant Initial Interest Period, LIBOR cannot be determined; or 

  

	14.2.2	before close of business in London on the applicable Quotation Day(s) during the relevant Initial Interest Period, any Interest Period during either the Commercial Loan Period or
the Power Loan Period or on the date the Lender is required to notify the Borrower of the Commercial Loan Period Swap Rate under Clauses 10.2 or 10.3 or the Power Loan Period Swap Rate under Clauses 11.2 or 11.3 the Lender determines that it is
unable to fund the Loans or Loans due to a disruption or impairment in the ability of market participants in general to effect credit transactions. 

  

	14.3	Notification of market disruption 

 The Lender shall
promptly notify the Borrower and each Lender of the occurrence and nature of a Market Disruption Event. 
  

	14.4	Suspension of Utilisation 

  

	14.4.1	If a Market Disruption Event occurs before an Advance is made, the Lender’s obligation to make the Advance shall be suspended while the circumstances giving rise to the Market
Disruption Event continue. 

  

	14.5	Basis of interest and funding 

  

	14.5.1	If a Market Disruption Event occurs in relation to the Loan or Loans then the rate of interest shall be the rate per annum which is the sum of: 

  

	 	(i)	the Margin for the Facility; 

  

	 	(ii)	the rate notified by the Lender to the Borrower which expresses as a percentage rate per annum the cost to the Lender of funding the Loan from whatever source it may reasonably
select; and 

  

	 	(iii)	the Mandatory Cost, if any, applicable to the Loan. 

  

	14.6	Alternative basis of interest or funding 

  

	14.6.1	If a Market Disruption Event occurs after an Advance is made and the Lender or the Borrower so requires, the Lender and the Borrower shall enter into negotiations (for a period of
not more than 30 days) with a view to agreeing a substitute basis for determining the rate of interest or (as the case may be) an alternative basis for funding. 

  

	14.6.2	Any substitute or alternative basis agreed pursuant to Clause 14.6.1 shall, with the prior consent of the Lender and the Borrower, be binding on all Parties to the Finance
Documents. 

  

	14.7	Break Costs 

  

	14.7.1	 The Borrower shall, within 3 Business Days of demand by the Lender (which demand shall enclose a certificate as referred to in Clause 14.7.2), pay to the Lender its
Break Costs (minus 

  

 29 

	 	 
any Break Gains) attributable to all or any part of the Loan or Loans being paid by the Borrower on a day other than (i) in respect of the repayment of
any Advance made prior to the Construction Period End Date, on the Construction Period End Date or on the last day of any Interest Period falling in the Construction Period; or (ii) in respect of payment of any Advance made during the Power
Loan Construction Period, on the Power Loan Construction Period End Date or on the last day of any Interest Period falling in such Power Loan Construction Period or (iii) in respect of any payment made in the amount and on the date set out in
the Repayment Schedules or any Replacement Repayment Schedule, on the relevant Repayment Date. If relevant, the Lender shall either pay to the Borrower, or set-off against such amounts as the Borrower may then owe to the Lender, any Break Gains.

  

	14.7.2	The Lender shall, with any demand referred to in Clause 14.7.1, provide a certificate confirming the amount of its Break Costs or Break Gains, for any Interest Period in which they
accrue. 

  

	15	ARRANGEMENT FEE 

 The Borrower shall pay to the
Lender for its own account a structuring fee of 1.25 per cent of the Total Commitment, payable upon the execution of this Agreement. 
  

 30 

 SECTION 6 
 ADDITIONAL PAYMENT AND PREPAYMENT OBLIGATIONS 
  

	16	TAX GROSS UP AND INDEMNITIES 

  

	16.1	Definitions 

  

	16.1.1	In this Agreement: 

 “Tax Credit” means a
credit against, relief or remission for, or repayment of any Tax. 
 “Tax Deduction” means a deduction or withholding for or
on account of Tax from a payment under a Finance Document. 
 “Tax Payment” means either an increase in a payment made by an
Obligor to the Lender under or pursuant to Clause 16.2 (Tax gross-up) or a payment under Clause 16.3 (Tax indemnity). 
  

	16.1.2	Unless a contrary indication appears, in this Clause 16 (TAX GROSS UP AND INDEMNITIES) a reference to “determines” or “determined”
means a determination made in the absolute discretion of the person making the determination. 

  

	16.2	Tax gross-up 

  

	16.2.1	Each Obligor shall make all payments to be made by it without any Tax Deduction, unless a Tax Deduction is required by law. 

  

	16.2.2	The Borrower shall promptly upon becoming aware that an Obligor must make a Tax Deduction (or that there is any change in the rate or the basis of a Tax Deduction) notify the Lender
accordingly. Similarly, the Lender shall notify the Borrower on becoming so aware in respect of a payment payable to the Lender. 

  

	16.2.3	If a Tax Deduction is required by law to be made by an Obligor, the amount of the payment due from that Obligor shall be increased to an amount which (after making any Tax
Deduction) leaves an amount equal to the payment which would have been due if no Tax Deduction had been required. 

  

	16.2.4	If an Obligor is required to make a Tax Deduction, that Obligor shall make that Tax Deduction and any payment required in connection with that Tax Deduction within the time allowed
and in the minimum amount required by law. 

  

	16.2.5	Within 30 days of making either a Tax Deduction or any payment required in connection with that Tax Deduction, the Obligor making that Tax Deduction shall deliver to the Lender
evidence reasonably satisfactory to the Lender that the Tax Deduction has been made or (as applicable) any appropriate payment paid to the relevant taxing authority. 

  

	16.3	Tax indemnity 

  

	16.3.1	The Borrower shall (within ten (10) Business Days of demand by the Lender) pay to the Lender an amount equal to the loss, liability or cost which the Lender determines will be
or has been (directly or indirectly) suffered for or on account of Tax by it in respect of a Finance Document. 

  

 31 

	16.3.2	Clause 16.3.1 shall not apply: 

  

	 	(a)	with respect to any Tax assessed on the Lender: 

  

	 	(i)	under the law of the jurisdiction in which the Lender is incorporated or, if different, the jurisdiction (or jurisdictions) in which the Lender is treated as resident for tax
purposes; or 

  

	 	(ii)	under the law of the jurisdiction in which the Facility Office is located in respect of amounts received or receivable in that jurisdiction, 

 if that Tax is imposed on or calculated by reference to the net income received or receivable (but not any sum deemed to be received or receivable) by
the Lender; or 
  

	 	(b)	to the extent a loss, liability or cost is compensated for by an increased payment under Clause 16.2 (Tax gross-up). 

  

	16.3.3	The Lender shall notify the Borrower in writing if it is making, or intending to make, a claim under Clause 16.3.1. 

  

	16.4	Tax Credit 

 If an Obligor makes a Tax Payment and
the Lender determines that: 
  

	 	(a)	a Tax Credit is attributable either to an increased payment of which that Tax Payment forms part or to that Tax Payment; and 

  

	 	(b)	the Lender has obtained, utilised and retained that Tax Credit, 

 the Lender shall pay an amount to the Obligor which the Lender determines will leave it (after that payment) in the same after-Tax position as it would have been in had the Tax Payment not been required to be made by the Obligor.

  

	16.5	Stamp taxes 

 The Borrower shall pay and, within ten
(10) Business Days of demand, indemnify the Lender against any cost, loss or liability the Lender incurs in relation to all stamp duty, registration and other similar Taxes payable in respect of any Finance Document. 
  

	16.6	Value added tax 

 All amounts set out, or expressed
to be payable under a Finance Document by any Obligor to the Lender which (in whole or in part) constitute the consideration for VAT purposes shall be deemed to be exclusive of any VAT which is chargeable on such supply, and accordingly, if VAT is
chargeable on any supply made by the Lender to any Obligor under a Finance Document, that Obligor shall pay to the Lender (in addition to and at the same time as paying the consideration) an amount equal to the amount of the VAT (and the Lender
shall promptly provide an appropriate VAT invoice to such Obligor). 
  

 32 

	17	INCREASED COSTS 

  

	17.1	Increased costs 

  

	17.1.1	Subject to Clauses 17.2.3 and 16.3, the Borrower shall, within 10 (ten) Business Days of a demand by the Lender, pay for the account of the Lender the amount of any Increased Costs
incurred by the Lender or any of its Affiliates as a result of: 

  

	 	17.1.1.1	the introduction of or any change in (or in the interpretation, administration or application of) any law or regulation or Applicable Law; or 

  

	 	17.1.1.2	compliance with any law or regulation or Applicable Law made after or which has effect after the date of this Agreement. 

  

	17.1.2	In this Agreement, “Increased Costs” means: 

  

	 	17.1.2.1	a reduction in the rate of return from the Facility or on the Lender’s (or its Affiliate’s) overall capital (including any reduction arising from the implementation of the
Basel II Accord or any subsequent accord of the Basel Committee for Banking Supervision from time to time); 

  

	 	17.1.2.2	an additional or increased cost; or 

  

	 	17.1.2.3	a reduction of any amount payable under any Finance Document, 

 which is incurred or suffered by the Lender or any of its Affiliates to the extent that it is attributable to the Lender having entered into the Total Commitment or funding or performing its obligations under any Finance Document.

  

	17.2	Increased cost claims 

  

	17.2.1	The Lender shall promptly notify the Borrower in writing of any event giving rise to a claim under Clause 17.1. 

  

	17.2.2	The Lender shall, as soon as reasonably practicable after notifying the Borrower under Clause 17.2.1, provide a certificate confirming the amount (and detailing all calculations) of
its Increased Costs and such details as the Lender then has and which are, in all the circumstances, reasonably available. 

  

	17.2.3	Following any Increased Cost as a result of the implementation of the Basel II Accord or any subsequent accord by the Basel II Committee for Banking Supervision, the Lender shall,
in addition to the certificate to be provided under 17.2.2, provide the Borrower with a Replacement Repayment Schedule for each of the Commercial Loan and the Power Loan which will show revised Repayment Instalments incorporating the amount of any
Increased Costs. 

  

	17.3	Exceptions 

 Clause 17.1 does not apply to the
extent any Increased Cost is: 
  

	17.3.1	attributable to a Tax Deduction required by law to be made by the Borrower; 

  

	17.3.2	compensated for by Clause 16.3 (or would have been compensated for under Clause 16.3 but was not so compensated solely because any of the exclusions in Clauses 16.3.2
applied); 

  

	17.3.3	compensated for by the payment of the Mandatory Cost; or 

  

 33 

	17.3.4	attributable to the wilful breach by the Lender or its Affiliates, or any breach arising directly as a result of gross negligence or negligent omission on the part of the Lender or
its Affiliates, of any law or regulation. 

  

	18	OTHER INDEMNITIES 

  

	18.1	Currency indemnity 

  

	18.1.1	If any sum due from an Obligor under the Finance Documents or any Finance Document (a “Sum”), or any order, judgment or award given or made in relation to a Sum,
has to be converted from the currency (the “First Currency”) in which the Sum is payable into another currency (the “Second Currency”) for the purpose of: 

  

	 	18.1.1.1	making or filing a claim or proof against that Obligor; or 

  

	 	18.1.1.2	obtaining or enforcing an order, judgment or award in relation to any litigation or arbitration proceedings, 

 that Obligor shall, as an independent obligation, within ten (10) Business Days of demand, indemnify the Lender against any cost, loss or liability
arising out of or as a result of the conversion including any discrepancy between (A) the rate of exchange used to convert that Sum from the First Currency into the Second Currency and (B) the rate or rates of exchange available to that
person at the time of its receipt of that Sum. 
  

	18.1.2	Each Obligor waives any right it may have in any jurisdiction to pay any amount under the Finance Documents in a currency or currency unit other than that in which it is expressed
to be payable. 

  

	18.2	Other indemnities 

 The Borrower shall, within ten
(10) Business Days of demand, indemnify the Lender against any Losses incurred by the Lender as a result of: 
  

	18.2.1	the occurrence of any Event of Default (whether or not later remedied); 

  

	18.2.2	any Approved Broker exercising any set-off in respect of any non-payment of insurance premiums by the Borrower or SAVVIS, Inc. or any Affiliate of SAVVIS, Inc. or the Borrower;

  

	18.2.3	the Lender reasonably having to request any separate insurance policy in accordance with Clause 29.9.2.5; 

  

	18.2.4	a failure by an Obligor to pay any amount due under a Finance Document on its due date; 

  

	18.2.5	funding, or making arrangements to fund, its participation in an Advance requested by the Borrower in a Utilisation Request but not made by reason of the operation of any provision
of this Agreement (other than by reason of wilful default or gross negligence by the Lender alone); or 

  

	18.2.6	the Loan(s) (or part of the Loan(s)) not being prepaid in accordance with a notice of prepayment given by the Borrower and the requirement(s) of any Finance Document(s).

  

 34 

	18.3	Further Indemnity to the Lender 

 The Borrower shall
promptly indemnify the Lender against any cost, loss or liability incurred by the Lender (acting reasonably) as a result of: 
  

	18.3.1	investigating any event which it reasonably believes is a Default; or 

  

	18.3.2	acting or relying on any notice, request or instruction given by the Borrower (other than those covered by Clause 20). 

  

	18.4	Time for Payment of Indemnity and Duration 

  

	18.4.1	Moneys becoming due from the Borrower under the indemnities contained in this Agreement shall (unless expressly stated otherwise) be paid within ten (10) Business Days of
demand, provided that the Lender has satisfied all notice obligations set out in this Clause 18. 

  

	18.5	Notwithstanding the provisions of this Clause 18, the Borrower shall have no obligation to the Lender under this Clause 18 or otherwise under this Agreement where a court of
competent jurisdiction finally determines the loss resulted from the gross negligence or wilful misconduct of the Lender. 

  

	19	MITIGATION BY THE LENDER 

  

	19.1	Mitigation 

  

	19.1.1	The Lender shall, in consultation with the Borrower, take all reasonable steps to mitigate any circumstances which arise and which would result in any amount becoming payable to it
under or pursuant to, or cancelled pursuant to, Clauses 16, 17 or 8.4 or paragraph 3 of Schedule 4 including transferring its rights and obligations under the Finance Documents to an Affiliate or another Facility Office. 

  

	19.1.2	Clause 19.1 does not in any way limit the obligations of the Borrower under the Finance Documents. 

  

	19.2	Limitation of liability 

  

	19.2.1	The Borrower shall indemnify the Lender for all costs and expenses reasonably incurred by the Lender as a result of steps taken by it under Clause 19.1. 

  

	19.2.2	The Lender is not obliged to take any steps under Clause 19.1 if, in its opinion (acting reasonably), to do so might be prejudicial to it. 

  

	20	COSTS AND EXPENSES 

  

	20.1	Transaction expenses 

 The Borrower shall promptly
within (subject to Clause 6.4.2) ten (10) Business Days of demand pay the Lender the amount of all costs and expenses (including legal fees) reasonably incurred by any of them in connection with the negotiation, re-negotiation, preparation,
printing, execution and/or syndication of: 
  

	20.1.1	this Agreement and any other documents referred to in this Agreement; and 

  

 35 

	20.1.2	any other Finance Documents executed after the date of this Agreement. 

  

	20.2	Amendment costs 

 If the Borrower requests an
amendment, waiver or consent to any provision of any Finance Document, the Borrower shall, within ten (10) Business Days of demand, reimburse the Lender for the amount of all costs and expenses (including legal fees) reasonably incurred by the
Lender negotiating, granting and/or complying (and/or entering into any agreement(s) in connection) with that request or requirement. 
  

	20.3	Enforcement costs 

 The Borrower shall, within ten
(10) Business Days of demand, pay to the Lender the amount of all costs and expenses (including legal fees) reasonably incurred by the Lender in connection with the enforcement of, or the preservation of any rights under, any Finance Document.

  

 36 

 SECTION 7 
 GUARANTEE 
  

	21	GUARANTEE AND INDEMNITY 

  

	21.1	Guarantee and indemnity 

 SAVVIS, Inc. irrevocably
and unconditionally: 
  

	21.1.1	guarantees to the Lender the punctual performance by the Borrower of all the Borrower’s obligations under the Finance Documents; 

  

	21.1.2	undertakes with the Lender that, whenever the Borrower does not pay any amount when due under or in connection with any Finance Document, SAVVIS, Inc. shall immediately on demand
pay that amount as if it were the principal obligor; and 

  

	21.1.3	indemnifies the Lender immediately on demand against any cost, loss or liability suffered by the Lender, if any obligation guaranteed by it is or becomes unenforceable, invalid or
illegal. The amount of the cost, loss or liability shall be equal to the amount which the Lender would otherwise have been entitled to recover. 

  

	21.2	Continuing guarantee 

 This guarantee is a
continuing guarantee and will extend to the ultimate balance of sums payable by any Obligor under the Finance Documents, regardless of any intermediate payment or discharge in whole or in part. 
  

	21.3	Reinstatement 

 If any payment by an Obligor or any
discharge given by the Lender (whether in respect of the obligations of any Obligor or any security for those obligations or otherwise) is avoided or reduced as a result of insolvency or any similar event: 
  

	21.3.1	the liability of each Obligor shall continue as if the payment, discharge, avoidance or reduction had not occurred; and 

  

	21.3.2	the Lender shall be entitled to recover the value or amount of that security or payment from each Obligor, as if the payment, discharge, avoidance or reduction had not occurred.

  

	21.4	Waiver of defences 

 The obligations of SAVVIS, Inc.
under this Clause 21 will not be affected by any act, omission, matter or thing which, but for this Clause 21, would reduce, release or prejudice any of its obligations under this Clause 21 (without limitation and whether or not known to it or the
Lender) including: 
  

	21.4.1	any time, waiver or consent granted to, or composition with, any Obligor or other person; 

  

	21.4.2	the release of any other Obligor or any other person under the terms of any composition or arrangement with any creditor of any member of the Group; 

  

 37 

	21.4.3	the taking, variation, compromise, exchange, renewal or release of, or refusal or neglect to perfect, take up or enforce, any rights against, or security over assets of, any Obligor
or other person, or any non-presentation or non-observance of any formality or other requirement in respect of any instrument or any failure to realise the full value of any security; 

  

	21.4.4	any incapacity or lack of power, authority or legal personality of or dissolution or change in the members or status of an Obligor or any other person; 

  

	21.4.5	any amendment, novation, supplement, extension, restatement (however fundamental and whether or not more onerous) or replacement of any Finance Document or any other document or
security including without limitation any change in the purpose of, any extension of or any increase in any facility or the addition of any new facility under any Finance Document or other document or security; 

  

	21.4.6	any unenforceability, illegality or invalidity of any obligation of any person under any Finance Document or any other document or security; or 

  

	21.4.7	any insolvency or similar proceedings. 

  

	21.5	Immediate recourse 

 SAVVIS, Inc. waives any right
it may have of first requiring the Lender (or any trustee or agent on its behalf) to proceed against or enforce any other rights or security or claim payment from any person before claiming from SAVVIS, Inc. under this Clause 21. This waiver applies
irrespective of any law or any provision of a Finance Document to the contrary. 
  

	21.6	Appropriations 

 Until all amounts which may be or
become payable by the Obligors under or in connection with the Finance Documents have been irrevocably paid in full, the Lender (or any trustee or agent on its behalf) may: 
  

	21.6.1	refrain from applying or enforcing any other moneys, security or rights held or received by the Lender (or any trustee or agent on its behalf) in respect of those amounts, or apply
and enforce the same in such manner and order as it sees fit (whether against those amounts or otherwise) and SAVVIS, Inc. shall not be entitled to the benefit of the same; and 

  

	21.6.2	hold in an interest-bearing suspense account any moneys received from SAVVIS, Inc. or on account of SAVVIS, Inc.’s liability under this Clause 21. 

  

	21.7	Deferral of SAVVIS, INC.’s’ rights 

  

	21.7.1	Until all amounts which may be or become payable by the Obligors under or in connection with the Finance Documents have been irrevocably paid in full and unless the Lender otherwise
directs, SAVVIS, Inc. will not exercise any rights which it may have by reason of performance by it of its obligations under the Finance Documents: 

  

	 	21.7.1.1	to be indemnified by the Borrower; 

  

	 	21.7.1.2	to claim any contribution from any other guarantor of the Borrower’s obligations under the Finance Documents; and/or 

  

 38 

	 	21.7.1.3	to take the benefit (in whole or in part and whether by way of subrogation or otherwise) of any rights of the Lender under the Finance Documents or of any other guarantee or
security taken pursuant to, or in connection with, the Finance Documents by any Lender. 

  

	21.7.2	If SAVVIS, Inc. receives any benefit, payment or distribution in relation to such rights it shall hold that benefit, payment or distribution to the extent necessary to enable all
amounts which may be or become payable to the Lender by the Obligors under or in connection with the Finance Documents to be repaid in full on trust for the Lender and shall promptly pay or transfer the same to the Lender for application in
accordance with Clause 33 (Payment mechanics) of this Agreement. 

  

	21.7.3	Until all amounts which may be or become payable by the Obligors under or in connection with the Finance Documents have been irrevocably paid in full or unless the Lender otherwise
directs, SAVVIS, Inc. will not: 

  

	 	21.7.3.1	claim any amount which may be due to it from the Borrower in respect of a payment under this Clause 21; 

  

	 	21.7.3.2	take or enforce any security for any such amount or in any other way seek to have recourse in respect of any such amount against any of the Borrower’s assets;

  

	 	21.7.3.3	set-off such amount against any sum due from SAVVIS, Inc. to the Borrower; or 

  

	 	21.7.3.4	prove for such an amount against the Borrower or its assets upon the occurrence of any of the events set out in Clauses 30.10, 30.11 or 30.12. 

  

	21.8	Additional security 

 This guarantee is in addition
to and is not in any way prejudiced by any other guarantee or security now or subsequently held by the Lender. 
  

 39 

 SECTION 8 
 REPRESENTATIONS, UNDERTAKINGS AND EVENTS OF DEFAULT 
  

	22	REPRESENTATIONS 

  

	22.1	General 

 Unless specified otherwise in the relevant
representation and warranty, each Obligor makes the representations and warranties set out in this Clause 22 to the Lender on the date of this Agreement and the Lender is relying on and shall rely on them throughout the Security Period. 

 

	22.2	Status 

  

	22.2.1	The Borrower is a private limited company, duly incorporated and validly existing in all respects under the law of England and Wales. 

  

	22.2.2	SAVVIS, Inc. is a corporation, duly incorporated and validly existing in all respects under the law of the State of Delaware, United States of America. 

  

	22.2.3	It has the power to, and has obtained all necessary consents, approvals and licences (none of which have been revoked) to own its assets and carry on its business as it is being
conducted. 

  

	22.3	Share capital and ownership 

  

	22.3.1	Details of the authorised share capital of the Borrower are set out in Schedule 1, Part I. 

  

	22.3.2	Details of the authorised share capital of SAVVIS, Inc. are as set out in Schedule 1 Part II. 

  

	22.4	Binding obligations 

 The obligations expressed to
be assumed by it in each Finance Document to which it is a party are, subject to any general principles of law limiting its obligations which are specifically referred to in any legal opinion delivered pursuant to Clause 4, legal, valid, binding and
enforceable obligations. 
  

	22.5	Status of security 

  

	22.5.1	Each Finance Document to which it is a party does now or, as the case may be, will, upon execution and delivery and, where applicable, registration, confer the Security Interests it
purports to confer over any assets to which such Security Interest, by its terms, relates, subject to any general principles of law limiting its obligations which are specifically referred to in any legal opinion delivered pursuant to any Finance
Documents. 

  

	22.5.2	Except for the Insurances the Borrower is the sole, lawful and beneficial owner of all the Security Assets free from any Security Interest other than Permitted Security Interests.

  

	22.5.3	SAVVIS, Inc. is the sole, lawful and beneficial owner of the Insurances and all rights relating thereto, free from any Security Interests, save those created under the Asset
Security Agreement and the other Permitted Security Interests. 

  

 40 

	22.6	Non-conflict with other obligations 

 The entry into
and performance by it of, and the transactions contemplated by, the Finance Documents to which it is a party do not and will not conflict with: 
  

	22.6.1	any law or regulation applicable to it; 

  

	22.6.2	its memorandum and articles of association (or any analogous constitutional documents in its jurisdiction of incorporation) or any other of its constitutional documents; or

  

	22.6.3	any agreement or instrument binding upon it or any of its assets the non-compliance with which, individually or in the aggregate, could reasonably be expected to result in a
Material Adverse Effect. 

  

	22.7	Power and authority 

  

	22.7.1	It has the power to enter into, perform and deliver, and has taken all necessary action (including obtaining any necessary consents or the like) to authorise its entry into,
performance and delivery of, the Finance Documents to which it is a party and the transactions contemplated by those documents. 

  

	22.8	No third party rights of termination 

 It has
obtained, and shall throughout the Security Period obtain, all consents necessary to ensure that no other party to any agreement or arrangement entered into by it, becomes entitled to terminate such agreement or arrangement as a consequence of it
entering into any Finance Document, the termination of which would or is likely to result in a Material Adverse Effect. 
  

	22.9	Validity and admissibility in evidence 

 All
Authorisations required or desirable: 
  

	22.9.1	to enable it lawfully to enter into, exercise its rights and comply with its obligations in the Finance Documents to which it is a party; and 

  

	22.9.2	to make the Finance Documents to which it is a party admissible in evidence in its jurisdiction of incorporation, 

 have been obtained or effected and are in full force and effect. 
  

	22.10	Governing Law and Enforcement 

 With regard to
SAVVIS, Inc., the choice of English law as the governing law of the Finance Documents to which it is a party will be recognised and enforced in its jurisdiction of incorporation and any judgement obtained in England in relation to a Finance Document
to which it is a party will be recognised and enforced in its jurisdiction of incorporation. 
  

	22.11	Deduction of Tax 

 As at the date of this Agreement,
it is not required to make any deduction for or on account of Tax from any payment it may make under any Finance Document to which it is a party. 
  

 41 

	22.12	No filing or stamp duties 

 With the exception of
any registrations at Companies House and any UCC filings, it is not necessary that the Finance Documents to which it is a party be filed, recorded or enrolled with any court or other authority in any jurisdiction or that any stamp duties,
registration or similar tax be paid on or in relation to those Finance Documents or the transactions contemplated by those Finance Documents. 
  

	22.13	No default 

  

	22.13.1	No Default is continuing or might reasonably be expected to result from the making of any Utilisation. 

  

	22.13.2	No other event or circumstance is outstanding which constitutes a default under any other agreement or instrument which is binding on it or to which its assets are subject which
will have a Material Adverse Effect. 

  

	22.14	No misleading information 

  

	22.14.1	Any information which has been provided in writing by or on behalf of any Obligor with respect to any Finance Document was true and accurate in all material respects as at the date
it was provided or as at the date (if any) at which it is stated. 

  

	22.14.2	The financial projections included in the information referred to in Clause 22.14.1 have been prepared on the basis of recent historical information and on the basis of
reasonable assumptions. 

  

	22.14.3	Nothing has occurred since the information referred to in Clause 22.14.1 was provided and no information has been given or withheld that results in such information being
untrue or misleading in any material respect. 

  

	22.15	Financial statements 

  

	22.15.1	The Original Financial Statements were prepared in accordance with US GAAP, consistently applied unless expressly disclosed to the Lender in writing to the contrary before the
date of this Agreement. 

  

	22.15.2	The Original Financial Statements fairly represent SAVVIS, Inc.’s. financial condition and operations during the relevant financial year. 

  

	22.15.3	There has been no material adverse change in its business or financial condition since the date to which the Original Financial Statements were drawn up. 

 

	22.16	Pari passu ranking 

 Its payment obligations under
the Finance Documents to which it is a party rank at least pari passu with the claims of all its other unsecured and unsubordinated creditors, except for obligations mandatorily preferred by law applying to companies generally. 
  

	22.17	No proceedings pending or threatened 

 Other than
those matters that reasonably could not be expected to result in a Material Adverse Effect or as otherwise previously disclosed by the Borrower to the Lender in writing, there are 

  

 42 

 
no litigation, arbitration or administrative proceedings of or before any court, arbitral body or agency (or, to the best of its knowledge and belief) been
started or threatened against the Borrower or SAVVIS, Inc. 
  

	22.18	Validity and completeness of the Construction Contracts 

  

	22.18.1	The Construction Contracts constitute valid, binding and enforceable obligations of the Contractors and the Borrower respectively in accordance with their terms.

  

	22.18.2	The copies of the Construction Contracts delivered to the Lender before the date of this Agreement are true and complete copies. 

  

	22.18.3	No amendments or additions to the Construction Contracts have been agreed nor has the Borrower or any Contractor waived any of their respective rights under the Construction
Contracts. 

  

	22.19	Milestones 

 The expected date for completion of
each of the Milestones, the details of the work to be completed in respect of each Milestone and the amount of the Advance required in respect of each Milestone, is as set out in Schedule 7 hereto. 
  

	22.20	Taxes paid 

 Each of SAVVIS, Inc. and the Borrower
has paid all Taxes applicable to, or imposed on or in relation to it or its business except where any non-payment would not or is unlikely to result in a Material Adverse Effect or where any such amounts are being contested in good faith and where
reserves are set aside for any such payment. 
  

	22.21	Solvency 

  

	22.21.1	It is not insolvent or unable to pay its debts (including subordinated and contingent debts), nor could it be deemed by a court to be unable to pay its debts within the meaning of
the law of the jurisdiction in which it is incorporated nor, in any such case, will it become so in consequence of entering into any Finance Document and/or performing any transaction(s) contemplated by any Finance Document.

  

	22.21.2	It has not taken any corporate action nor (to the best of its knowledge and belief) has any legal proceedings or other procedure or step been taken, started or threatened in
relation to anything referred to in Clause 30.11 or for its Winding-up or the commencement of its Winding-up, or for the appointment of a receiver, administrative receiver, trustee or similar officer of any or all of its assets or revenues.

  

	22.22	Title in the Data Centre Assets 

 The Borrower is
the sole legal and beneficial owner and has a good and marketable title (free and clear of any Security Interest other than Permitted Security Interests) to the Data Centre Assets. 
  

	22.23	Performance of covenants relating to Land 

 The
Borrower has properly performed all material covenants affecting the Land and the Borrower has not received any notice of any outstanding breach of covenant as regards the 

  

 43 

 
Land which is likely materially and adversely to affect the value of any Security or the right of the Borrower or the Lender to enter upon the Land for the
purpose of retrieving the Data Centre Assets. 
  

	22.24	Development 

 The Borrower has on or before the date
of this Agreement obtained all permissions, consents and licences in respect of the Land in order to enable the construction and operation of the Slough Data Centre and no situation exists in relation to the Land in respect of which an enforcement
notice has been delivered or may be delivered. 
  

	22.25	Disposal of prior rights 

 Before the date of this
Agreement, neither the Borrower nor SAVVIS, Inc. has: 
  

	22.25.1	sold or granted any rights of pre-emption over or agreed to sell or grant any right of pre-emption over the Security Assets; or 

  

	22.25.2	Except for the security interest granted by SAVVIS, Inc. to Wells Fargo Foothill, Inc over certain shares in the Borrower, transferred or agreed to transfer any rights it may have
in or to any shares in the Borrower. 

  

	22.26	Environmental matters 

 The Borrower is in
compliance with all Environmental Laws, the non-compliance with which, individually or in the aggregate, could reasonably be expected to result in a Material Adverse Effect and it has obtained, and shall, throughout the Security Period, maintain and
be in compliance with, all Environmental Approvals, the non-compliance with which, individually or in the aggregate, could reasonably be expected to result in a Material Adverse Effect. 
  

	22.27	Information 

  

	22.27.1	All information supplied by or on behalf of the Borrower or SAVVIS, Inc. to the Lender in connection with the Finance Documents and the transactions contemplated by them is complete
and accurate in all material respects; and 

  

	22.27.2	Neither the Borrower nor SAVVIS, Inc. has knowingly withheld any information which if disclosed may reasonably be expected adversely to affect the decision of the Lender considering
whether or not to make further Advances to the Borrower. 

  

	22.27.3	SAVVIS Procurement Corporation was merged out of existence on December 17, 2007. 

  

	22.27.4	The Series A Subordinated Indebtedness Subordination Agreement referred to (and defined in) in the Wells Fargo Facility is no longer subsisting as all of the Series A Subordinated
Notes (as defined in the Wells Fargo Facility) to which it applies have been paid in full. 

  

	22.28	Repetition 

 Unless a representation is expressed to
be given at a specific date, the Repeating Representations are deemed to be made by the Obligors by reference to the facts and circumstances then existing on the date of each Utilisation Request and the first day of each Interest Period. 

 

 44 

	23	INFORMATION UNDERTAKINGS 

  

	23.1	Duration 

 The undertakings in this Clause 23
remain in force throughout the Security Period except as the Lender may otherwise permit. 
  

	23.2	Financial statements 

 The Borrower shall supply to
the Lender: 
  

	23.2.1	as soon as they become available, but in any event within 120 days after the end of each of its financial years its audited consolidated financial statements for that financial year
prepared in accordance with UK GAAP; 

  

	23.2.2	as soon as they become available, but in any event within 40 days after the end of each quarter of SAVVIS, Inc.’s financial year, the unaudited consolidated financial
statements of SAVVIS, Inc. for that financial quarter; 

  

	23.2.3	as soon as they become available, but in any event within 90 days after the end of SAVVIS, Inc.’s financial year, the audited consolidated financial statements of SAVVIS, Inc.
for that financial year; 

  

	23.2.4	an annual budget for the Europe, Middle East and Asia regions (“EMEA”) and profit and loss, balance sheet and cash flows for that financial year within 14 days of
the approval thereof by the Board of Directors of SAVVIS, Inc. or by 31 January in each year, whichever is earlier; 

  

	23.2.5	the Management Report for EMEA in respect of every financial month or other shorter period for which EMEA produces such information (each a “Relevant Period”)
within one week of circulation of the same by the Borrower’s management to its Board of Directors and in any event within 60 days of the end of the Relevant Period; and 

  

	23.2.6	such other additional management financial information reasonably requested by the Lender. 

  

	23.3	Requirements as to financial statements 

  

	23.3.1	Each set of financial statements delivered by the Borrower pursuant to Clause 23.2 shall be certified by one officer of SAVVIS, Inc. or the Borrower as fairly representing its
financial condition as at the date at which those financial statements were drawn up. 

  

	23.3.2	SAVVIS, Inc. shall procure that each set of financial statements delivered pursuant to Clause 23.2 for SAVVIS, Inc. is prepared using US GAAP. 

  

	23.4	Specific Information 

  

	23.4.1	During the Construction Period the Borrower shall promptly notify the Lender of any dispute over the terms of any Construction Contract which may have a Material Adverse Effect and
shall provide the Technical Adviser with information regarding how such disputes are being resolved. 

  

	23.4.2	The Borrower shall as soon as reasonably practicable, and in any event within 5 Business Days following receipt, deliver to the Lender and the Technical Adviser copies of monthly
progress reports received by the Borrower under the terms of the Construction Contracts or any other construction or operating contract. 

  

 45 

	23.4.3	If the Borrower becomes aware that, for any reason, the date for performance of any Milestone, the details thereof, or the amount of the Advance required in respect thereof, is to
change, the Borrower must notify the Lender forthwith in writing. If the Technical Adviser, acting reasonably, agrees such change in writing by notice to the Borrower and the Lender, then, subject to Clause 23.4.4, the parties agree that the Works
Schedule shall be deemed to be amended accordingly in respect of the attached Milestone. Provided that in no event may the Works Schedule be amended to allow for the completion of any Milestone after 31 December 2008 unless otherwise agreed in
writing in advance by the Lender. 

  

	23.4.4	For the avoidance of doubt, no amendment referred to in Clause 23.4.3 shall be requested by the Borrower nor agreed by the Lender or the Technical Adviser if such amendment would
result in: (i) the Borrower requiring to borrow more than the Total Commitment; or (ii) the Borrower requiring any Advance (other than to Slough Heat & Power, or to make the Final Nova Payment), after 31 December 2008.

  

	23.5	Information: miscellaneous 

  

	23.5.1	Each of the Obligors shall, promptly upon becoming aware of them, notify the Lender in writing of the details of any material litigation, arbitration or administrative proceedings
which are current, threatened in writing or pending against it. 

  

	23.5.2	Each of the Obligors shall promptly supply to the Lender, such further information regarding its financial condition, business and operations as the Lender may reasonably request.

  

	23.6	Notification of Default 

  

	23.6.1	Each of the Obligors shall notify the Lender of any Default (and the steps, if any, being taken to remedy it) promptly upon becoming aware of its occurrence.

  

	23.6.2	Promptly upon a request by the Lender, the relevant Obligor shall supply to the Lender a certificate signed by two of its directors or senior officers on its behalf certifying that
no Default is continuing (or if a Default is continuing, specifying the Default and the steps, if any, being taken to remedy it). 

  

	23.7	“Know your customer” checks 

  

	23.7.1	If: 

  

	 	23.7.1.1	the introduction of or any change in (or in the interpretation, administration and/or application of) any law or regulation made after the date of this Agreement;

  

	 	23.7.1.2	any change in the status of the Borrower or SAVVIS, Inc. (or the composition of the Borrower’s shareholders) after the date of this Agreement; or 

  

	 	23.7.1.3	a proposed assignment or transfer by the Lender of any of its rights and obligations under this Agreement to a party that is not the Lender prior to such assignment or transfer,

 obliges the Lender to comply with “know your customer” or similar identification procedures in circumstances where
the necessary information is not already available to it, the Borrower shall promptly upon the request of the Lender supply, or procure the supply of, such documentation and other evidence as is reasonably requested by the Lender in order for the
Lender to carry 

  

 46 

 
out and be satisfied it has complied with all necessary “know your customer” or other similar checks under all applicable laws and regulations
pursuant to the transactions contemplated in the Finance Documents. 
  

	23.8	General Information 

 The Borrower shall provide the
Lender with such information in writing concerning the Borrower’s and SAVVIS, Inc.’s business, operations and affairs or the Security Assets as the Lender may, from time to time, reasonably require and shall permit the Lender and its
representatives and advisers free access at all reasonable times and on reasonable notice to inspect and take copies and extracts from the books, accounts and other records of the Borrower and SAVVIS, Inc. at the Lender’s expense. 

 

	24	FINANCIAL COVENANTS 

  

	24.1	Financial Definitions 

 For the purposes of this
Clause 24, the following terms are defined as meaning: 
 “Adjusted EBITDA” means, for any period, income or loss from
operations before depreciation, amortisation, accretion, non-cash equity-based compensation and gains or losses on asset sales. 
 “Capital Expenditure” means capital expenditure as defined by US GAAP. 
 “Capital Lease” means a
lease that is required to be capitalised for financial reporting purposes in accordance with US GAAP. 
 “Capitalised Lease
Obligation” means that portion of the obligations under a Capital Lease that is required to be capitalised in accordance with US GAAP. 
 “Cash Interest Expense” means, for any period, an amount for SAVVIS, Inc. and its consolidated subsidiaries equal to net interest expense and other as reported as a line item in SAVVIS, Inc.’s Consolidated Statement of
Operations for that period less (i) interest income, other income or loss, amortisation and current period interest expense accruals all determined in conformity with US GAAP; plus (ii) any cash payments for prior period interest expense
and capitalised interest. 
 “Consolidated Statement of Operations” means the consolidated statement of operations in SAVVIS,
Inc.’s consolidated financial statements. 
 “Excess Cash Flow” means, for any period, net cash provided by operating
activities for SAVVIS, Inc. and its consolidated subsidiaries, determined in conformity with US GAAP, less cash Capital Expenditure. 
 “Senior Debt” means, for any period, Total Debt for SAVVIS, Inc. and its consolidated subsidiaries, less any unsecured indebtedness and Capitalised Lease Obligations. 
 “Total Debt” means, for any period, an amount for SAVVIS, Inc. and its consolidated subsidiaries, equal to long-term debt determined in
conformity with US GAAP, plus Capitalised Lease Obligations. 
  

 47 

	24.2	Financial covenants 

 SAVVIS, Inc. shall comply with
each of the financial covenants set out in the clauses below: 
  

	24.2.1	Interest Cover Ratio 

 The ratio of Adjusted EBITDA
to Cash Interest Expense for each 12 Month period ending on each date set out in Clause 24.3.1 shall not be less than 1.5:1 
  

	24.2.2	Total Debt Cover Ratio 

 The ratio of Total Debt to
Adjusted EBITDA for each 12 Month period ending on each date set out in Clause 24.3.1 shall not exceed 5.5:1. 
  

	24.2.3	Senior Debt Cover Ratio 

 The ratio of Senior Debt
to Adjusted EBITDA as at the end of each 12 Month period ending on each date set out in Clause 24.3.1 shall not exceed 3.0:1. 
  

	24.3	Testing of covenants 

  

	24.3.1	The Financial Covenants shall be tested on each Quarter End Date first by reference to the most recent unaudited accounts of SAVVIS, Inc. delivered pursuant to Clause 23.2.2, and
then by reference to the most recent audited accounts delivered pursuant to Clause 23.2.3. 

  

	24.3.2	For the purposes of testing the Financial Covenants, Adjusted EBITDA shall be calculated on the basis of Adjusted EBITDA for the previous three (3) Month period multiplied by
four (4). The Borrower may elect (by giving notice to the Lender) to calculate the Financial Covenants on the basis of Adjusted EBITDA for the previous 12 Month period (rather than the previous three Month period multiplied by four) for any testing
period. 

  

	24.3.3	SAVVIS, Inc. shall provide the Lender with a certificate from a director of SAVVIS, Inc. confirming the ratios achieved for that period and confirmation as to whether or not SAVVIS,
Inc. is in compliance with Clause 24 at the same time as its consolidated unaudited financial statements are delivered to the Lender. 

  

	25	LETTER OF CREDIT 

  

	25.1	Provision of Original Letter of Credit 

  

	25.1.1	The Borrower will cause SAVVIS, Inc. or an Affiliate of SAVVIS, Inc. to procure that a Letter of Credit Bank provides the Lender with a legally binding US Dollar Letter of Credit in
a form approved by the Lender, acting reasonably, as completed in accordance with Clause 25.1, (the “Original Letter of Credit”). 

  

	25.1.2	The Original Letter of Credit shall be delivered by using SWIFT to The Royal Bank of Scotland Plc, acting as advising bank, not later than the Construction Period End Date.

  

	 25.1.3
	 The Original Letter of Credit shall be expressed automatically to renew annually (unless the Lender receives at least 60
days written notice of cancellation from the relevant Letter of Credit Bank) until at least 31 December 2013. 

  

 48 

	25.1.4	The maximum amount (“LC Amount”) expressed to be payable in US Dollars under the Original Letter of Credit (as at the Construction Period End Date) shall be the
amount (converted into Dollars using the exchange rate applicable five Business Days prior to the Construction Period End Date) equal to £7,000,000 (seven million pounds). 

  

	25.1.5	No later than ten (10) Business Days prior to the date which is twelve months after the Construction Period End Date, the Borrower will procure that the Letter of Credit Bank
at that point in time will issue a notice delivered by using SWIFT to The royal Bank of Scotland Plc, as advising bank. Such notice shall confirm that the LC Amount shall be increased to an amount (converted into Dollars using the exchange rate
applicable five Business Days prior to the date of such notice) equal to £10,500,000 (ten million five hundred thousand pounds). 

  

	25.1.6	No later than ten (10) Business Days prior to the date which is eighteen months after the Construction Period End Date, the Borrower will procure that the Letter of Credit Bank
at that point in time will issue a notice electronically by using SWIFT to the Royal Bank of Scotland Plc, as advising bank. Such notice shall confirm that the LC Amount shall be increased to an amount (converted into Dollars using the exchange rate
applicable five Business Days prior to the date of such notice) equal to £14,000,000 (fourteen million pounds). 

  

	25.1.7	For the period from the first repayment date following the Construction Period End Date to the second anniversary of such date and each successive three (3) month period
thereafter, the Lender shall, within ten (10) Business Days of the end of each such period, at the request of the Borrower, countersign a notice which will have the effect of reducing the LC Amount for next such period by the amount of any
principal payments in excess of £1,750,000 received by the Lender during the previous period. 

  

	25.2	Interest Letter of Credit 

  

	25.2.1	The Borrower will cause SAVVIS, Inc. or an Affiliate of SAVVIS, Inc. to procure that a Letter of Credit Bank provides the Lender with a legally binding US Dollar Letter of Credit in
the form approved by the Lender, acting reasonably, (the “Interest Letter of Credit”). 

  

	25.2.2	The Interest Letter of Credit (duly executed by the Letter of Credit Bank) shall, subject to Clause 4.2.3.2, be delivered to The Royal Bank of Scotland Plc, as advising bank, by
using SWIFT, not later than the day before the first Utilisation Date. 

  

	25.2.3	The Interest Letter of Credit shall be expressed automatically to renew annually (unless the Lender receives at least 60 days written notice of cancellation from the relevant Letter
of Credit Bank) until the date which is one month after the last Repayment Date for all the Loans. 

  

	25.2.4	The maximum amount expressed to be payable in US Dollars under the Interest Letter of Credit shall be the amount (converted into Dollars using the exchange rate applicable five
Business Days prior to the date of such Interest Letter of Credit) equal to £242,083.333. 

  

	25.3	Claim under and Release of Letter of Credit 

  

	25.3.1	At any time after the occurrence of an Event of Default, the Lender may make a claim under the Original Letter of Credit and/or the Interest Letter of Credit upon the terms and for
the maximum amount specified therein at the date of demand thereunder, and shall apply any amount received under the Letter of Credit in or towards satisfaction of any amount due by the Borrower or SAVVIS, Inc. under any Finance Document.

  

 49 

	25.3.2	Unless the Lender has made a claim under the Original Letter of Credit, the Lender shall return the Original Letter of Credit to the issuer on the day after its Expiration Date (as
defined in the Original Letter of Credit). 

  

	25.4	Replacement Letter of Credit 

  

	25.4.1	The Borrower will cause SAVVIS, Inc. or an Affiliate of SAVVIS, Inc. to procure that a legally binding further Letter of Credit or Letters of Credit, in a form approved by the
Lender, acting reasonably, and as completed in accordance with Clause 25.4 (the “Replacement Letter(s) of Credit”) is or are delivered to the Lender: 

  

	 	25.4.1.1	at any time during the Security Period, within five (5) Business Days of the current Letter of Credit Bank ceasing to have a Standard & Poor’s long term credit
rating of at least A-; and/or 

  

	 	25.4.1.2	no later than thirty (30) days after the date on which the Lender or the advising bank receives notice from the Letter of Credit Bank that the Original Letter of Credit or the
Interest Letter Credit, or any replacement thereof, is not being extended. 

  

	25.4.2	Any Replacement Letter of Credit shall, in the circumstances outlined in 25.4.1.1, have an Expiration Date which is the same as the current Letter of Credit it is replacing and, in
the circumstances outlined in 25.4.1.2, will have an Expiration Date of one month after the last Repayment Date. 

  

	25.4.3	The maximum amount expressed to be payable in US Dollars under the Replacement Letter of Credit shall be the amount set out in the Letter of Credit it is replacing.

  

	25.4.4	At any time prior to 31 January 2011, SAVVIS, Inc. shall deliver a certificate together with the Borrower’s Business Report for Slough based on the Borrower’s latest
management report to the Lender, signed by one of its directors, certifying whether or not the Borrower has achieved £9,000,000 in cumulative EBITDA (as defined in the Borrower’s Business Forecast for Slough) less cash-funded capital
expenditures (as defined in the Borrower’s Business Forecast for Slough) for the Slough Data Centre (the “LC Release Amount”), as tested against the unaudited consolidated financial statements for SAVVIS, Inc. for the
applicable period. 

  

	25.4.5	If the Borrower does not achieve the LC Release Amount as specified in Clause 25.4.4, then SAVVIS, Inc. shall re-test the Borrower’s cumulative EBITDA (as defined in the
Borrower’s Business Forecast for Slough) less cash-funded capital expenditures (as defined in the Borrower’s Business Forecast for Slough) on the last day of any month and shall certify to the Lender in the same way set out in accordance
with Clause 25.4.4 (together with the Borrower’s Business Report for Slough dated the last day of such month) whether or not the Borrower has achieved the LC Release Amount. Until the Borrower has achieved the LC Release Amount, the Borrower
shall continue to cause SAVVIS, Inc. or an Affiliate to procure that the Original Letter of Credit, Replacement Letter of Credit or a further Replacement Letter of Credit remains in full force and effect. 

  

	25.4.6	Once the Borrower has achieved the LC Release Amount in accordance with Clause 25.4.4 or 25.4.5 and has certified to the Lender accordingly the Original Letter of Credit or any
replacement thereof shall be released by the Lender within ten (10) Business Days of the later of: (i) 31 January 2011; and (ii) receipt by the Lender of a valid certificate from the Borrower, or such earlier date as the Lender
may agree in its reasonable discretion. 

  

 50 

	26	[DELIBERATELY LEFT BLANK] 

  

	27	GENERAL UNDERTAKINGS 

  

	27.1	Duration 

 The undertakings in this Clause 27 remain
in force throughout the Security Period except as the Lender may otherwise permit. 
  

	27.2	Authorisations 

 The Borrower shall promptly:

  

	27.2.1	obtain, comply with and do all that is necessary to maintain in full force and effect; and 

  

	27.2.2	at the request of the Lender supply certified copies to the Lender of each and every Authorisation required under any law or regulation of its jurisdiction of incorporation or
Applicable Law(s) to enable each of it and SAVVIS, Inc. to: 

  

	 	27.2.2.1	perform its obligations under the Finance Documents to which it is a party and the Construction Contracts; and 

  

	 	27.2.2.2	ensure the legality, validity, enforceability or admissibility in evidence in its jurisdiction of incorporation of any Finance Document to which it is a party; and

  

	 	27.2.2.3	own, construct and operate the Data Centres. 

  

	27.3	Compliance with laws 

 The Borrower shall and shall
procure that SAVVIS, Inc. shall comply in all respects with all laws to which it or the Data Centres may be subject, if failure so to comply would materially impair its ability to perform its obligations under the Finance Documents to which it is a
party. 
  

	27.4	Title 

  

	27.4.1	The Borrower undertakes that throughout the Security Period, it shall be the sole, lawful and beneficial owner of all the Data Centre Assets (the subject of the Security Agreement
it has entered into) and either it or SAVVIS, Inc (subject as set out in this Clause below) shall be the owner of all the Insurances, free from any Security Interest other than Permitted Security Interests. If any Affiliate of the Borrower other
than SAVVIS, Inc., is the owner of the Insurances, the Borrower shall procure that such Affiliate shall enter into a security agreement substantially similar in form to the Asset Security Agreement acceptable to the Lender, acting reasonably, in
relation to such Insurances in favour of the Lender. 

  

	27.4.2	SAVVIS, Inc. and the Borrower shall, individually or collectively, provide the Insurances covering the Security Assets. 

  

	27.4.3	The Borrower will: 

  

	 	27.4.3.1	observe and perform all material restrictive and other material covenants, burdens, servitudes, stipulations and obligations now or at any time affecting any Land insofar as the
same are subsisting and are capable of being enforced; and 

  

 51 

	 	27.4.3.2	duly and diligently enforce all material restrictive or other material covenants, burdens, servitudes, stipulations and obligations benefiting any Land and not waive, release or
vary (or agree to do so) the obligations of any other party thereto. 

  

	27.5	Negative pledge 

  

	27.5.1	The Borrower shall not create nor purport to create or permit to subsist any floating charge over all or substantially all of its assets. 

  

	27.5.2	The Borrower shall not create nor purport to create or permit Security Interest (except for Permitted Security Interests) over: 

  

	 	27.5.2.1	any or all of the Land; or 

  

	 	27.5.2.2	any or all of its present and future revenues, assets, undertakings or shares and/or the Security Assets. 

  

	27.6	Disposals 

  

	27.6.1	The Borrower may only dispose of any of the Data Centre Assets in accordance with the terms of the Asset Security Agreement. Subject to the terms of the Asset Security Agreement,
any sales proceeds received in respect of any Class A Data Centre Assets, shall be used to repay the Loans, subject to and in accordance with Clause 8.2.1.1. 

  

	27.7	CAPEX Loans 

 The Borrower may not incur any
Financial Indebtedness for capital expenditure purposes after the date of this Agreement with any Affiliate unless the Borrower and such Affiliate agree to subordinate and postpone the repayment of such obligations as more fully set forth in the
Intercompany UK Debt Subordination Agreement. 
  

	27.8	Merger 

 The Borrower shall not enter into any
amalgamation, demerger, merger or corporate reconstruction without the prior consent of the Lender. 
  

	27.9	Borrower’s Business 

 The Borrower shall:

  

	27.9.1	not suspend or cease or threaten to suspend or cease to carry on all or a substantial part of its Business; 

  

	27.9.2	not make any substantial change in the nature of the Business in which it is engaged on the date of this Agreement; 

  

	27.9.3	acquire, maintain and renew all rights, contracts, powers, privileges, licences, leases, sanctions, franchises and concessions necessary or desirable for the conduct of its business
and operations; and 

  

	27.9.4	preserve its corporate existence. 

  

 52 

	27.10	Registration of Security Interest 

 The Borrower and
SAVVIS, Inc. shall each (at its own cost) ensure that each and every filing, notation and/or registration required, advisable and/or desirable (from the perspective of the Lender) under Applicable Law(s) in connection with (and/or to reflect and/or
give notice of): 
  

	27.10.1	the Security Agreements; and/or 

  

	27.10.2	any Security Interest(s) created, or intended or purported to be created under the Security Agreements; and/or 

  

	27.10.3	any Data Centre, including any Land; 

 is (or are) fully
and properly effected within any applicable time limits that are relevant under Applicable Law(s). 
  

	27.11	Share capital 

 The Borrower shall not purchase,
cancel or redeem any of its share capital. 
  

	27.12	Dividends 

 The Borrower shall not pay or make any
dividend or other distribution (in cash or in kind) in respect of its share capital. 
  

	27.13	Investments 

 The Borrower shall not: 
  

	 	(a)	provide any form of credit or financial assistance to: 

  

	 	(i)	a person who is directly or indirectly interested in the Borrower’s share or loan capital; or 

  

	 	(ii)	any company in or with which such a person is directly or indirectly interested or connected, 

 or enter into any transaction with or involving such a person or company on terms which are, in any respect, less favourable to the Borrower than those
which it could obtain in a bargain made at arms’ length; 
  

	 	(b)	acquire any shares or other securities other than US or UK Treasury bills and certificates of deposit issued by major North American or European banks. 

  

	27.14	Acquisitions 

 The Borrower shall not be permitted
to acquire any assets outside the ordinary course of business or any interest in or to any freehold or leasehold premises unless the Borrower has first demonstrated to the Lender that SAVVIS, Inc. will not at the time of acquisition or at any time
thereafter by reason of such acquisition breach any covenant pursuant to Clause 24.1 (Financial Covenants). 
  

 53 

	27.15	Winding-up, corporate existence, etc 

 Neither
Obligor shall, without the prior written consent of the Lender: 
  

	27.15.1	take steps with a view to the commencement of its Winding-up; or 

  

	27.15.2	take any action which may prejudice its corporate existence or its right or ability to carry on its business and operations. 

  

	27.16	Preferential Payments 

 Each of the Obligors shall
punctually pay, as they become due, subject to any applicable grace periods, all debts and liabilities which by law would have priority over the Secured Liabilities (except to the extent that any such amounts are being contested in good faith and
where adequate reserves are set aside for any such payment). 
  

	27.17	Performance of Construction Contracts 

 The Borrower
shall: 
  

	27.17.1	promptly pay all amounts payable to any party under any Construction Contracts as and when they become due (except to the extent that any such amounts are being contested in good
faith and where adequate reserves are set aside for any such payment) where failure to do so is reasonably likely to have a Material Adverse Effect; and 

  

	27.17.2	comply with and take all reasonable and practical steps to preserve and enforce its rights and pursue any claims and remedies arising under any Construction Contract where failure
to do so is reasonably likely to have a Material Adverse Effect. 

  

	27.18	Filing 

 Each Obligor shall file, record or enrol
any Finance Documents with any court or other authority in any jurisdiction to the extent necessary or desirable and shall notify the Lender thereof. 
  

	28	SPECIFIC UNDERTAKINGS 

  

	28.1	Duration 

 The undertakings in this Clause 28 remain
in force throughout the Security Period except as the Lender may otherwise permit (such consent not to be unreasonably withheld or delayed). 
  

	28.2	Data Centre Start-up and Operation 

 The Borrower
shall: 
  

	28.2.1	ensure that with respect to any Data Centre, any and all licences, consents, approvals and/or registrations required, desirable and/or advisable under Applicable Law(s) relating to
each Data Centre (whether with respect to the maintenance and/or operation of each Data Centre or otherwise), are effected, obtained and maintained at all times during the Security Period; and 

  

	28.2.2	not do or allow to be done anything as a result of which any such material registration, consents, approval or licence might be cancelled or imperilled. 

  

 54 

	28.3	Repair, etc. 

 The Borrower shall keep and maintain
the Data Centre Assets in a good and safe condition and state of repair, and shall repair and/or replace as necessary, to no less an extent than would a reasonably prudent owner and operator of assets, land, units, etc., similar to each Data Centre
(acting in accordance with and having full regard to (i) any supplier’s and/or manufacturers recommendations and (ii) normal industry practice, standards and requirements applicable to assets, land, units, etc., similar to each Data
Centre). 
  

	28.4	Alterations 

 The Borrower will not, at any time,
without the prior written consent of the Lender, effect, carry out or permit any demolition, reconstruction or rebuilding of or any structural alteration to, or material change in the use of, any Data Centre or any Land. 
  

	28.5	Removal and Disposal of Data Centre Assets 

  

	28.5.1	The Borrower will not at any time, without the prior written consent of the Lender, sever, unfix or remove any of the Data Centre Assets (except as provided in the Asset Security
Agreement.). 

  

	28.6	Notices 

 The Borrower will promptly give full
particulars (and if requested a copy of any written particulars received by the Borrower or SAVVIS, Inc.) to the Lender of any material, order, directive, designation, resolution or proposal having application to a Land or to the area in which it is
situate by any planning or other authority. 
  

	28.7	Pay rents charges and Taxes 

  

	28.7.1	The Borrower will punctually pay or cause to be paid all existing and future rents, taxes, duties, fees, renewal fees, charges, assessments, impositions and outgoings whatsoever
whether imposed by deed or by statute or otherwise and whether in the nature of capital or revenue and even though of a wholly novel character which are or become payable in respect of Land (except to the extent that any such amounts are being
contested in good faith and where adequate reserves are set aside for any such payment). 

  

	28.7.2	In relation to SDLT, the Borrower shall, and shall procure that the Borrower shall, promptly notify the Lender of and comply with all audits and assessments from the HM
Revenue & Customs, make all such payments and adjustments in respect of SDLT (including payment of interest and penalties where appropriate) that may be due or may be assessed by the HM Revenue & Customs from time to time
(including interest penalties) (except to the extent that any such amounts are being contested in good faith and where adequate reserves are set aside for any such payment). 

  

	28.8	Compliance with laws and supplier’s recommendations applicable to Data Centres 

 The Borrower shall ensure that each Data Centre is and/or will: 
  

	28.8.1	comply with and be constructed, operated, repaired, kept and maintained in accordance with each and every Applicable Law, consent, approval, authorisation, licence and/or
registration relating to (or applicable to) any part of such Data Centre other than to the extent that non compliance does not have a Material Adverse Effect; 

  

 55 

	28.8.2	be constructed, operated, repaired, kept and maintained in accordance with the recommendations of the manufacturer or supplier of any part of any Data Centre other than to the
extent that non-compliance thereof does not have a Material Adverse Effect; and 

  

	28.8.3	comply with any title and leasehold covenants affecting the Land. 

  

	28.9	Inspection 

 The Borrower shall procure that the
Lender may at all reasonable times inspect the Security Assets (and any technical documents relating to any part thereof) and shall afford all proper facilities for such inspections and shall make available all technical documents relating to the
Data Centre Assets for such inspections after 10 Business days notice from the Lender. 
  

	28.10	The Borrower shall permit the Technical Adviser access to all documents, receipts, invoices, technical notes as well as all areas of each Data Centre (with all necessary and proper
safety equipment and/or clothing) after ten (10) Business Days prior notice from Lender. 

  

	28.11	Compliance with environmental laws etc. 

 The
Borrower shall: 
  

	28.11.1	comply, or procure compliance with all Environmental Laws and Environmental Approvals and all other laws or regulations or Applicable Law(s) relating to each and/or any Data Centre,
its ownership, operation and management or to its business other than to the extent that non compliance does not have a Material Adverse Effect; 

  

	28.11.2	obtain, comply with and do all that is necessary to maintain in full force and effect any Environmental Approvals, including compliance with any statutory remediation notice,
failure of which would have a Material Adverse Effect; and 

  

	28.11.3	not employ any Data Centre Asset nor allow its employment in any manner contrary to any law or regulation or Applicable Law(s) in any relevant jurisdiction where the same would have
a Material Adverse Effect. 

  

	28.12	Notification of certain events 

 The Borrower shall
promptly upon it or SAVVIS, Inc. becoming aware of the same notify the Lender by fax, confirmed forthwith by letter, of: 
  

	28.12.1	any requirement to investigate, survey or audit the state and condition of any Data Centre; or 

  

	28.12.2	any requirement or recommendation made in relation to any Data Centre by any insurer or by any competent or relevant body or authority which is not immediately complied with;

  

	28.12.3	any exercise or purported exercise of any lien on any Data Centre; and/or 

  

	28.12.4	any Environmental Claim made against the Borrower or SAVVIS, Inc. in connection with any Data Centre Asset or any Environmental Incident at the Data Centres;

 and the Borrower shall keep the Lender advised in writing on a regular basis and in such detail as the Lender shall
reasonably require of its or any other person’s response to any of those events or matters. 
  

 56 

	28.13	Change or replacement of Contractors 

 The Borrower
shall notify the Lender of any proposal to change or replace the principal Contractor (Nova CM Limited) and shall obtain prior written consent from the Lender, such consent not to be unreasonably withheld or delayed, prior to changing or replacing
such principal Contractor. 
  

	28.14	No movement 

 The Borrower shall not move or
transfer any Data Centre Asset from its location at any Data Centre save as set out in the Asset Security Agreement. 
  

	29	INSURANCE UNDERTAKINGS 

  

	29.1	Duration 

 The undertakings in this Clause 29 remain
in force throughout the Security Period except as the Lender may otherwise permit. 
  

	29.2	Obligatory insurances 

 The Borrower shall keep each
Data Centre Asset operated by it and/or SAVVIS, Inc. or shall procure that each such Data Centre Asset is kept insured by any Affiliate of SAVVIS, Inc. at its expense as follows: 
  

	29.2.1	property insurance coverage against fire, theft and all other usual risks normal for a similar type of business naming as insured parties the Borrower and the Lender, as appropriate
and naming the Lender as Loss Payee; and 

  

	29.2.2	liability coverage against all third party and product liability claims for which the Borrower or the Lender is legally liable. 

  

	29.2.3	The Borrower is obliged to ensure that either an Affiliate of the Borrower or all Contractors and other appropriate parties advising on the design and construction of the Slough
Data Centre maintain the following insurances for the relevant Construction Period: 

  

	 	(i)	Contractors’ All Risks, covering all works and materials for full reinstatement value naming as insured parties the Borrower and the Lender, as appropriate and naming the
Lender as Loss Payee and Additional Insured; 

  

	 	(ii)	Third Party Liability cover for a minimum amount of £1 million any one occurrence naming as insured parties the Borrower and the Lender and naming the Lender as
Additional Insured. 

 The Borrower shall provide the Lender with evidence of the insurances above in a form reasonably
satisfactory to the Lender. 
  

	29.3	Terms of obligatory insurance 

 SAVVIS, Inc. or the
Borrower shall effect the obligatory insurances set out in clause 29.2 in relation to all Data Centre Assets: 
  

	29.3.1	in Sterling or US Dollars equivalent to the then required Sterling amount; 

  

 57 

	29.3.2	in an amount on an agreed value basis of at least the greater: 

  

	 	(i)	110% per cent of the aggregate of the Loans then outstanding; and 

  

	 	(ii)	the full replacement cost of the Data Centre Assets from time to time; 

  

	29.4	Further terms of obligatory insurances 

 The
Borrower and SAVVIS, Inc. shall procure that the obligatory insurances referred to in Clauses 29.2.1 and 29.2.3: 
  

	29.4.1	name the Lender as an additional named insured; 

  

	29.4.2	provide that the obligatory insurances shall be primary without right of contribution from other insurances which may be carried by the Lender; and 

  

	29.4.3	provide that the Lender may make proof of loss if SAVVIS, Inc. or the Borrower fails to do so. 

  

	29.5	Use of Insurance proceeds 

  

	29.5.1	Save as set out in Clause 8.2.1.2, except for any monies received in respect of third party liability insurance, all moneys which may at any time hereafter be received or receivable
under any insurance policy in respect of the Data Centre Assets, whether or not effected pursuant to the foregoing provisions, shall be applied, forthwith upon receipt of such proceeds in repairing or replacing the Affected Data Centre Assets (as
defined in Clause 8.2.1.2). 

  

	29.6	Renewal of obligatory insurances 

 The Borrower
shall: 
  

	29.6.1	not later than 5 Business Days before the expiry date of any obligatory insurance effected by it: 

  

	 	29.6.1.1	procure that the Approved Broker notifies the Lender of the Approved Insurer with which the Borrower proposes to renew that obligatory insurance and of the proposed terms of
renewal; and 

  

	 	29.6.1.2	obtain the Lender’s, if required, approval to the matters referred to in Clause 29.6.1.1 above; and 

  

	29.6.2	not later than 5 Business Days before the expiry date of any obligatory insurance effected by it, renew that obligatory insurance in accordance with the Lender’s approval
pursuant to Clause 29.6.1. 

  

	29.7	Notification of renewal of obligatory insurances 

 The Borrower shall procure that the Approved Broker with which a renewal of any obligatory insurance is effected shall, at renewal, notify the Lender in writing of the terms and conditions of the renewal. 
  

 58 

	29.8	Notification of non-renewals, cancellations and material changes 

 The Borrower shall procure that the Approved Insurers with which any obligatory insurance had been effected shall notify the Lender within 30 days of any cancellation, non renewal or material change in any obligatory
insurance. 
  

	29.9	Copies of policies; letters of undertaking 

  

	29.9.1	The Borrower shall ensure that the Approved Broker provides the Lender with certificates of insurance relating to the obligatory insurances which it is to effect or renew.

  

	29.9.2	The Borrower shall procure that the Approved Broker provides the Lender with a letter of undertaking in the form satisfactory to the Lender (acting reasonably) and including
undertakings by the Approved Insurer or Approved Brokers (as the case may be) that: 

  

	 	29.9.2.1	they will have endorsed on each relevant policy, immediately upon issue, an additional insured clause complying with Clause 29.4.1; 

  

	 	29.9.2.2	they will advise the Lender immediately of any material change to the terms of the obligatory insurances; 

  

	 	29.9.2.3	they will notify the Lender if they have not received notice of renewal instructions from the relevant Borrower or its Lenders not less than 5 days before the expiry of the
obligatory insurances; and 

  

	 	29.9.2.4	they will notify, or procure that the Approved Insurers will notify, the Lender if they have received instructions to renew and of the terms of the instructions;

  

	 	29.9.2.5	they will arrange for a separate policy to be issued in respect of the Data Centre Assets forthwith upon being so requested by the Lender at the cost of the Lender and upon the
Lender executing such fee letter as the Approved Broker may reasonably require. 

  

	29.10	Deposit of original policies 

 The Borrower and/or
SAVVIS, Inc., as appropriate, shall procure that all policies relating to obligatory insurances are deposited with the Approved Brokers through which the insurances are effected or renewed. 
  

	29.11	Payment of premiums 

 The Borrower shall punctually
pay all premiums or other sums payable in respect of the obligatory insurances and produce all relevant receipts when so reasonably required by the Lender. 
  

	29.12	Compliance with terms of insurances 

  

	29.12.1	Neither SAVVIS, Inc. nor the Borrower shall do nor omit to do (or permit to be done or not to be done) any act or thing which would or might render any obligatory insurance invalid,
void, voidable or unenforceable or render any sum payable under an obligatory insurance repayable in whole or in part. 

  

 59 

	29.12.2	Without limiting Clause 29.12.1, SAVVIS, Inc. or any of its Affiliates shall take all necessary action and comply with all requirements which may from time to time be applicable to
the obligatory insurances, and ensure that the obligatory insurances are not made subject to any exclusions or qualifications to which the Lender has not given its prior approval. 

  

	29.13	Alteration to terms of obligatory insurances 

 SAVVIS, Inc. or any of its Affiliates shall not make or agree to any alteration to the terms of any obligatory insurance or waive any right relating to any obligatory insurance without the prior written consent of the Lender (such consent
not be unreasonably withheld or delayed). 
  

	29.14	Power to Remedy 

 In case of default by the Borrower
and/or SAVVIS, Inc. under this Clause 29 the Lender, after providing 5 Business Days advance notice, may effect such insurances as the Lender may consider necessary or desirable. The Borrower will keep the Lender indemnified against all losses,
costs, charges and expenses incurred in connection with the exercise of the powers contained in this Clause 29. 
  

	29.15	Settlement of claims 

  

	29.15.1	Neither the Borrower nor SAVVIS, Inc. shall settle, compromise or abandon any claim under any obligatory insurance relating to the Data Centre Assets for Total Loss or for a Major
Claim. 

  

	29.15.2	The Borrower shall do all things necessary and provide all documents, evidence and information to enable the Lender to collect or recover any moneys which at any time become payable
in respect of the obligatory insurances. 

  

	30	EVENTS OF DEFAULT 

  

	30.1	General 

 Each of the events or circumstances set
out in this Clause 30 is an Event of Default. 
  

	30.2	Non-payment 

 The Borrower and/or SAVVIS, Inc. does
not pay on the due date any amount payable pursuant to a Finance Document at the place at and in the currency in which it is expressed to be payable and such payment remains unpaid for 5 (five) Business Days after its due date. 
  

	30.3	Specific obligations 

  

	30.3.1	A breach occurs of any term(s) and/or requirement(s) of Clauses 4.2.3 (Waiver of Conditions Precedent) 27.4 (Title), 27.5 (Negative pledge) and 29.2 (Obligatory Insurances) and such
breach is not capable of being cured within 5 (five) Business days. 

  

	30.3.2	A breach occurs of any of the covenants contained in Clause 24 . 

  

	30.3.3	There is a failure to perform any of the obligations contained in Clause 25 or Clause 4.2.3.2(i). 

  

 60 

	30.4	Other obligations 

  

	30.4.1	The Borrower and/or SAVVIS, Inc. does not comply with any provision(s) of any Finance Document(s) (other than those referred to in Clauses 30.2 and 30.3). 

 

	30.4.2	No Event of Default under Clause 30.4.1 will occur if the failure to comply is capable of remedy in full (in the Lender’s opinion acting reasonably) and is remedied within 30
days of the occurrence of the failure. 

  

	30.5	Misrepresentation 

 Any representation (including,
but not limited to the representations in Clause 24 (Financial Covenants)), conditions precedent or statement made or deemed to be made by the Borrower or SAVVIS, Inc. in any Finance Document(s) or any other document delivered by or on behalf
of the Borrower or SAVVIS, Inc. under or in connection with any Finance Document is or proves to have been incorrect or misleading in any material respect when made or deemed to be made and is not remedied within 30 days of the date the same is made
or deemed to be made. 
  

	30.6	Cross default 

  

	30.6.1	Any Financial Indebtedness of the Borrower and/or SAVVIS, Inc. is not paid when due nor within any originally applicable grace period. 

  

	30.6.2	Any Financial Indebtedness of the Borrower and/or SAVVIS, Inc. is declared to be or otherwise becomes payable before its specified maturity as a result of an event of default
(however described). 

  

	30.6.3	Any commitment for any Financial Indebtedness of the Borrower and/or SAVVIS, Inc. is cancelled or suspended by a creditor as a result of an event of default (however described).

  

	30.6.4	Any creditor of the Borrower and/or SAVVIS, Inc. becomes entitled to declare any Financial Indebtedness payable before its specified maturity as a result of an event of default
(however described). 

  

	30.6.5	Any Security Interest securing any Financial Indebtedness of the Borrower or SAVVIS, Inc. becomes enforceable. 

  

	30.6.6	Save in relation to any Financial Indebtedness of the Borrower under this Agreement no Event of Default will occur under Clauses 30.6.1 to 30.6.5 if (after any applicable grace
period) the aggregate amount of Financial Indebtedness, or commitment for Financial Indebtedness, falling within Clauses 30.6.1 to 30.6.5 is less than £5 million (or its equivalent in any other currency). 

  

	30.6.7	An event of default or any similar termination event occurs in a lease, loan or any other financing document entered into between any Lender or any member of the Lender’s Group
and any member of the Group, and such Lender or member of the Lender’s Group shall have given notice under such lease, loan or other financing document to terminate, cancel or accelerate payment under the same and any amounts falling due on
such termination, cancellation or acceleration are not paid when due or within any applicable grace period. 

  

 61 

	30.7	Default under Wells Fargo Facility 

  

	30.7.1	Any amount due and payable by SAVVIS, Inc. or any Affiliate under the Wells Fargo Facility is declared to be or otherwise becomes payable before its specified maturity as a result
of an event of default or any mandatory prepayment provision thereunder (however described). 

  

	30.8	Property 

 The Landlord terminates the
Borrower’s rights to occupy any material part of the Land pursuant to any right the Landlord has to do so. 
  

	30.9	Contractor 

 Following a material default by Nova CM
Limited under the terms of its Construction Contract, if the Borrower fails within 3 months of such default to procure that the Construction Contract is performed by a replacement contractor such replacement contractor to be agreed by the Lender
(whose consent shall not be reasonably withheld or refused). 
  

	30.10	Insolvency 

  

	30.10.1	Any of the following occurs in respect the Borrower or SAVVIS, Inc.: 

  

	 	30.10.1.1	it is, or is deemed for the purposes of any law to be, unable to pay its debts as they fall due or is insolvent; 

  

	 	30.10.1.2	it admits its inability to pay its debts as they fall due; 

  

	 	30.10.1.3	it suspends making payments on any of its debts or announces an intention to do so; 

  

	 	30.10.1.4	by reason of actual or anticipated financial difficulties, it commences negotiations with any of its creditors (or any class thereof) with a view to rescheduling any of its
indebtedness; or 

  

	 	30.10.1.5	a moratorium is declared in respects of any of its indebtedness 

 or any analogous procedure or step is taken in any jurisdiction. 
  

	30.10.2	If a moratorium occurs in respect of the Borrower or SAVVIS, Inc., the ending of the moratorium will not remedy any Event of Default caused by the moratorium.

  

	30.10.3	The value of the assets of the Borrower or SAVVIS, Inc. is less than its liabilities (taking into account contingent and prospective liabilities). 

  

	30.11	Insolvency proceedings 

  

	30.11.1	Any corporate action, legal proceedings or other procedure or step is taken in respect of the Borrower and/or SAVVIS, Inc.: 

  

	 	30.11.1.1	the suspension of payments, a moratorium of any indebtedness, winding-up, dissolution (save where such proceedings, procedures or steps is (or are) frivolous or vexatious and is (or
are) discharged or withdrawn within 30 days of commencement), administration, examinership or reorganisation (by way of voluntary arrangement, scheme of arrangement or otherwise) of the Borrower or SAVVIS, Inc.; 

  

 62 

	 	30.11.1.2	a composition, compromise, assignment or arrangement with any of its creditors of Borrower or SAVVIS, Inc.; 

  

	 	30.11.1.3	the appointment of a liquidator, receiver, examiner, administrator, administrative receiver, compulsory manager or other similar officer in respect of it or any of its assets;

  

	 	30.11.1.4	enforcement of any Security Interest over all or any material part of the assets of its assets and not discharged within 15 Business Days; 

  

	 	30.11.1.5	an order for the Winding Up, administration, examinership or dissolution is made in relation to it; 

 or any analogous procedure or step is taken in any jurisdiction. 
  

	30.12	Creditors’ process 

 Any expropriation,
attachment, sequestration, distress or execution affects any asset or assets of the Borrower or SAVVIS, Inc. with an aggregate value in excess of £2,000,000 (or its equivalent in any other currency) and is not discharged within 15 Business
Days. 
  

	30.13	Ownership and Control of the Borrower and SAVVIS, Inc. 

  

	30.13.1	The Borrower is not or ceases to be a Subsidiary of SAVVIS, Inc.; or 

  

	30.13.2	There is any change of control of SAVVIS, Inc. from that existing at the date of this Agreement and for the purposes of this Agreement, “change of control” means that any
“person” or “group” (within the meaning of Sections 13(d) and 14(d) of the US Securities Exchange Act 1934, as amended (the “Exchange Act”), other than Welsh, Carson, Andersen & Stowe and its Affiliates,
becomes the beneficial owner (as defined in Rule 13d-3 under the Exchange Act) directly or indirectly, of 50% or more, of the stock of SAVVIS, Inc. having the right to vote for the election of members of the Board of Directors.

  

	30.14	Cessation of business 

  

	30.14.1	The Borrower and/or SAVVIS, Inc. ceases or suspends carrying on its business or any material part of it. 

  

	30.15	Construction Contracts 

  

	30.15.1	Any Construction Contract is altered or changed in such as way as to have a Material Adverse Effect. 

  

	30.15.2	Any material Construction Contract is terminated before the Construction Period End Date, other than by reason of the completion of all the obligations of the Contractor thereunder
or any Contractor fails to fulfil its material obligations under any Construction Contract and an alternative contractor has not been appointed within three months of such failure. 

  

 63 

	30.16	Unlawfulness 

 It is or becomes unlawful for:

  

	30.16.1	the Borrower and/or SAVVIS, Inc. to perform any of its obligations under the Finance Documents; or 

  

	30.16.2	for the Lender to exercise or enforce any of its rights under, or any Security Interest created by, the Finance Documents. 

  

	30.17	Security 

 Any Security Interest (or any Security
Agreement) and/or indemnity is not in full force and effect or is repudiated or the Borrower and/or SAVVIS, Inc. repudiates a Finance Document or evidences an intention to repudiate a Finance Document. 
  

	30.18	Ranking of security 

 Any Security Interest created
by a Finance Document proves to have been or becomes invalid or unenforceable or such Security Interest proves to have ranked after, or loses its priority to, any other Security Interest. 
  

	30.19	Failure to Achieve Milestones 

 The Borrower fails
to provide evidence to the Lender’s satisfaction (acting reasonably) that all of the Milestones have been achieved in accordance with the Works Schedule (as may be amended from time to time pursuant to Clause 23.4.3) on or prior to
31 December 2008. 
  

	30.20	Material Adverse Effect 

 Any event or circumstance
occurs which has or is reasonably likely to have a Material Adverse Effect. 
  

	30.21	Acceleration 

 On and at any time after the
occurrence of an Event of Default which is continuing at such time the Lender may by notice to the Borrower: 
  

	30.21.1	cancel the Total Commitments, whereupon they shall immediately be cancelled; 

  

	30.21.2	declare that all or part of the Advances made during the Construction Period or the Power Loan Construction Period or the Loans (as appropriate), together with accrued interest, and
all other amounts accrued or outstanding (including, but not limited to, Break Costs (minus any Break Gains)) under the Finance Documents be immediately payable, whereupon they shall become immediately payable; and/or 

  

	30.21.3	declare that all or part of the Loans be payable on demand, whereupon it shall immediately become payable on demand by the Lender. 

  

	30.22	Enforcement of security 

 On and at any time after
the occurrence of an Event of Default which is continuing at such time the Lender may take any action which, as a result of the Event of Default or any notice served under Clause 30.21, the Lender is entitled to take under any Finance Document or
any applicable law or regulation. 
  

 64 

 SECTION 8 
 CHANGES TO PARTIES 
  

	31	ASSIGNMENT BY THE LENDER 

  

	31.1	Assignment by the Lender 

 The
Lender may assign any of its rights under the Finance Documents to an Affiliate of the Lender or to an OECD bank with a Standard & Poors rating of at least A. 
  

	31.2	Disclosure of information 

 The
Lender may disclose to any of its Affiliates and any other person: 
  

	 	(a)	to (or through) whom the Lender assigns (or may potentially assign) all or any of its rights under this Agreement; 

  

	 	(b)	with (or through) whom the Lender enters into (or may potentially enter into) any sub-participation in relation to, or any other transaction under which payments are to be made by
reference to, this Agreement or any Obligor; or 

  

	 	(c)	to whom, and to the extent that, information is required to be disclosed by any applicable law or regulation, 

 any information about any Obligor, the Group and the Finance Documents as the Lender shall consider appropriate, provided that in relation
to any disclosure under sub-clauses (a) and (b) above, the person to whom the information is to be disclosed has entered into a confidentiality undertaking either in Loan Market Association recommended form or as may otherwise be
reasonably agreed between the Lender and the Borrower. 
  

	32	CHANGES TO THE OBLIGORS 

 Neither Obligor may assign
any of its rights or transfer any of its rights or obligations under the Finance Documents. 
  

 65 

 SECTION 10 
 ADMINISTRATION AND INDEMNITIES 
  

	33	PAYMENT MECHANICS 

  

	33.1	Payments 

  

	33.1.1	On each date on which an Obligor or the Lender is required to make a payment under a Finance Document, the Obligor or the Lender (as appropriate) shall make the same available to
the Lender or that Obligor for value on the due date at the time and in such funds specified by the Lender as being customary at the time for settlement of transactions in the relevant currency in the place of payment. 

  

	33.2	Application of receipts; partial payments 

  

	33.2.1	Except as any Finance Document may otherwise provide, any payment that is received or recovered by the Lender under or in connection with any Finance Document or pursuant to the
enforcement of the rights of the Lender under or pursuant to any Finance Document shall be applied in the following order: 

  

	 	(a)	first, in or towards payment of any amounts then due and payable to the Lender under any of the Finance Documents, and 

  

	 	(b)	secondly, any surplus shall be paid to the Borrower or to any other person who appears to be entitled to it. 

  

	33.2.2	If the Lender receives a payment that is insufficient to discharge all the amounts then due and payable by the Obligors under the Finance Documents, the Lender shall apply that
payment towards the obligations of the Obligors under the Finance Documents in the following order: 

  

	 	(a)	first, in or towards payment pro rata of any unpaid fees, costs and expenses of the Lender under the Finance Documents; 

  

	 	(b)	secondly, in or towards payment pro rata of any accrued interest, fee or commission payable but unpaid under this Agreement; 

  

	 	(c)	thirdly, in or towards payment pro rata of any principal payable but unpaid under this Agreement; and 

  

	 	(d)	fourthly, in or towards payment pro rata of any other sum payable but unpaid under the Finance Documents. 

  

	33.2.3	The Lender may vary the order set out in Clause 33.2.2, acting reasonably. 

  

	33.2.4	Clause 33.2.1, Clause 33.2.2 and Clause 33.2.3 will override any appropriation made by an Obligor. 

 Amendment No. 9 to Credit Agreement 
  

 66 

	33.3	No set-off by Obligors 

 All
payments to be made by an Obligor under the Finance Documents shall be calculated and be made without (and free and clear of any deduction for) set-off or counterclaim. 
  

	33.4	Business Days 

  

	33.4.1	Any payment which is due to be made on a day that is not a Business Day shall be made on the next Business Day in the same calendar month (if there is one) or the preceding Business
Day (if there is not). 

  

	33.4.2	During any postponement of the due date for payment of any principal or Unpaid Sum under this Agreement, interest is payable on the principal or Unpaid Sum at the rate payable on
the original due date. 

  

	33.5	Currency of account 

  

	33.5.1	Subject to Clause 33.5.2 and Clause 33.5.3, Sterling is the currency of account and payment for any sum due from an Obligor under any Finance Document.

  

	33.5.2	Each payment in respect of costs, expenses or Taxes shall be made in the currency in which the costs, expenses or Taxes are incurred. 

  

	33.5.3	Any amount expressed to be payable in a currency other than Sterling shall be paid in that other currency. 

  

	33.6	Change of currency 

  

	33.6.1	Unless otherwise prohibited by law, if more than one currency or currency unit is at the same time recognised by the central bank of any country as the lawful currency of that
country, then: 

  

	 	(a)	any reference in the Finance Documents to, and any obligations arising under the Finance Documents in, the currency of that country shall be translated into, or paid in, the
currency or currency unit of that country designated by the Lender (after consultation with the Borrower); and 

  

	 	(b)	any translation from one currency or currency unit to another shall be at the official rate of exchange recognised by the central bank for the conversion of that currency or
currency unit into the other, rounded up or down by the Lender (acting reasonably). 

  

	33.6.2	If a change in any currency of a country occurs, this Agreement will, to the extent the Lender (acting reasonably and after consultation with the Borrower) specifies to be
necessary, be amended to comply with any generally accepted conventions and market practice in the Relevant Interbank Market and otherwise to reflect the change in currency. 

  

	33.7	Disruption to Payment Systems etc. 

 If either the
Lender determines (in its discretion) that a Disruption Event has occurred or the Lender is notified by the Borrower that a Disruption Event has occurred: 
  

	33.7.1	the Lender may, and shall if requested to do so by the Borrower, consult with the Borrower with a view to agreeing with the Borrower such changes to the operation or administration
of the Facility as the Lender may deem necessary in the circumstances; 

  

 67 

	33.7.2	the Lender shall not be obliged to consult with the Borrower in relation to any changes mentioned in Clause 33.7.1 if, in its opinion, it is not practicable to do so in the
circumstances and, in any event, shall have no obligation to agree to such changes; 

  

	33.7.3	any such changes agreed upon by the Lender and the Borrower shall (whether or not it is finally determined that a Disruption Event has occurred) be binding upon the Parties as an
amendment to (or, as the case may be, waiver of) the terms of the Finance Documents notwithstanding the provisions of Clause 40 (AMENDMENTS AND WAIVERS); 

  

	33.7.4	the Lender shall not be liable for any damages, costs or losses whatsoever (including, without limitation for negligence, gross negligence or any other category of liability
whatsoever but not including any claim based on the fraud of the Lender) arising as a result of its taking, or failing to take, any actions pursuant to or in connection with this Clause 33.7. 

  

	34	SET-OFF 

 The Lender may set off any matured
obligation due from an Obligor under the Finance Documents against any matured obligation owed by the Lender to that Obligor, regardless of the place of payment, booking branch or currency of either obligation. If the obligations are in different
currencies, the Lender may convert either obligation at a market rate of exchange in its usual course of business for the purpose of the set-off. 
  

	35	NOTICES 

  

	35.1	Communications in writing 

 Any communication to be
made under or in connection with the Finance Documents shall be made in writing and, unless otherwise stated, may be made by fax, letter or telex. 
  

	35.2	Addresses 

 Subject to Clause 44, the address, fax
number and telex number (and the department or officer, if any, for whose attention the communication is to be made) of each Party for any communication or document to be made or delivered under or in connection with the Finance Documents is that
specified in Schedule 1 Part I (The Parties ) or any substitute address, fax number, telex number or department or officer as the Party may notify to the other Party by not less than five Business Days’ notice. 
  

	35.3	Delivery 

  

	35.3.1	Subject to Clause 44, any communication or document made or delivered by one person to another under or in connection with the Finance Documents will only be effective:

  

	 	(a)	if by way of fax, when received in legible form; or 

  

 68 

	 	(b)	if by way of letter, when it has been left at the relevant address or five Business Days after being deposited in the post postage prepaid in an envelope addressed to it at that
address; or 

  

	 	(c)	if by way of telex, when despatched, but only if, at the time of transmission, the correct answerback appears at the start and at the end of the sender’s copy of the notice,

 and, if a particular department or officer is specified as part of its address details provided under
Clause 35.2 (Addresses ), if addressed to that department or officer. 
  

	35.3.2	Any communication or document made or delivered to the Borrower in accordance with this Clause will be deemed to have been made or delivered to each of the Obligors.

  

	35.4	English language 

  

	35.4.1	Any notice given under or in connection with any Finance Document must be in English. 

  

	35.4.2	All other documents provided under or in connection with any Finance Document must be: 

  

	 	(a)	in English; or 

  

	 	(b)	if not in English, and if so required by the Lender, accompanied by a certified English translation and, in this case, the English translation will prevail unless the document is a
constitutional, statutory or other official document. 

  

	36	CALCULATIONS AND CERTIFICATES 

  

	36.1	Accounts 

 In any litigation or arbitration
proceedings arising out of or in connection with a Finance Document, the entries made in the accounts maintained by the Lender are prima facie evidence of the matters to which they relate. 
  

	36.2	Certificates and determinations 

 Any certification
or determination by the Lender of a rate or amount under any Finance Document is, in the absence of manifest error, conclusive evidence of the matters to which it relates. 
  

	36.3	Day count convention 

 Any interest, commission or
fee accruing under a Finance Document will accrue from day to day and will be calculated on the basis of the actual number of days elapsed and a year of 365 days or, in any case where the practice in the Relevant Interbank Market differs, in
accordance with that market practice. 
  

 69 

	37	CONDUCT OF BUSINESS BY THE LENDER 

  

	37.1	Conduct of business 

 No provision of this Agreement
will: 
  

	 	(a)	interfere with the right of the Lender to arrange its affairs (tax or otherwise) in whatever manner it thinks fit; 

  

	 	(b)	oblige the Lender to investigate or claim any credit, relief, remission or repayment available to it or the extent, order and manner of any claim; or 

  

	 	(c)	oblige the Lender to disclose any information relating to its affairs (tax or otherwise) or any computations in respect of Tax. 

  

	38	PARTIAL INVALIDITY 

 If, at any time, any provision
of the Finance Documents is or becomes illegal, invalid or unenforceable in any respect under any law of any jurisdiction, neither the legality, validity or enforceability of the remaining provisions under the law of that jurisdiction nor the
legality, validity or enforceability of such provision under the law of any other jurisdiction will in any way be affected or impaired. 
  

	39	REMEDIES AND WAIVERS 

 No failure to exercise, nor
any delay in exercising, on the part of the Lender, any right or remedy under the Finance Documents shall operate as a waiver, nor shall any single or partial exercise of any right or remedy prevent any further or other exercise or the exercise of
any other right or remedy. The rights and remedies provided in this Agreement are cumulative and not exclusive of any rights or remedies provided by law. 
  

	40	AMENDMENTS AND WAIVERS 

 Any term of the Finance
Documents may be amended or waived only with the consent of the Lender and the Obligors and only subject to the terms of the Intercreditor Agreement. Any such amendment or waiver will be binding on all Parties. 
  

	41	COUNTERPARTS 

 Each Finance Document may be executed
in any number of counterparts, and this has the same effect as if the signatures on the counterparts were on a single copy of the Finance Document. 
  

	42	GOVERNING LAW 

 This Agreement is governed by
English law. 
  

 70 

	43	ENFORCEMENT 

  

	43.1	Jurisdiction 

  

	43.1.1	Subject to Clause 43.1.3, the courts of England have exclusive jurisdiction to settle any dispute arising out of or in connection with this Agreement (including a dispute regarding
the existence, validity or termination of this Agreement) (a “Dispute”). 

  

	43.1.2	The Parties agree that the courts of England are the most appropriate and convenient courts to settle Disputes and accordingly no Party will argue to the contrary.

  

	43.1.3	The Lender shall not be prevented from taking proceedings relating to a Dispute in any other courts with jurisdiction. To the extent allowed by law, the Lender may take concurrent
proceedings in any number of jurisdictions. 

  

	44	AGENT FOR SERVICE OF PROCESS 

 Without prejudice to
any other mode of service allowed under any relevant law, SAVVIS, Inc. irrevocably appoints the Borrower as its agent for service of process in relation to any proceedings before the English courts in connection with this Agreement and SAVVIS, Inc.
agrees that failure by a process agent to notify it of the process will not invalidate the proceedings concerned. The Borrower hereby accepts such appointment. 
 This Agreement has been entered into on the date stated at the beginning of this Agreement. 
  

 71 

 EXECUTION PAGES 
 BORROWER 
  

					
	 SIGNED by
 for and on behalf of
	 	 )
 )
	  	 /s/ Jeffrey H. Von
Deylen                                        
                

	 SAVVIS UK LIMITED
 acting by
	 	Director
			
		 		  	 /s/ Edward Mueller

		
		 	Director/Secretary
			
	GUARANTOR	 		  	
			
	 SIGNED by
 for and on behalf of
	 	 )
 )
	  	 /s/ Jeffrey H. Von Deylen

	SAVVIS, INC.	 	)	  	Chief Financial Officer
		 	)	  	
	LENDER	 		  	
			
	 SIGNED by
 for and on behalf of
	 	 )
 )
	  	
	 LOMBARD NORTH CENTRAL PLC in the
 presence of:

	 	 )
 )
	  	 /s/ P. A. Stranaghan

  

 72Asset Security Agreement

 Exhibit 10.2 
 Dated 27 June 2008 
 SAVVIS UK LIMITED 
 (as Borrower) 
 and 
 SAVVIS, INC. 
 (as Guarantor) 
 and 
 LOMBARD NORTH CENTRAL PLC 

 (as Lender) 
 ASSET SECURITY AGREEMENT 
 relating to 
 a term loan facility agreement 
 dated 27 June 2008 

 CONTENTS 
  

					
	 1
	  	 DEFINITIONS AND INTERPRETATION
	  	1
	 2
	  	 COVENANT TO PAY
	  	4
	 3
	  	 FIXED SECURITY
	  	5
	 4
	  	 DECLARATION OF TRUST
	  	6
	 5
	  	 GENERAL UNDERTAKINGS
	  	6
	 6
	  	 INSURANCE UNDERTAKINGS
	  	8
	 7
	  	 DATA CENTRE ASSETS UNDERTAKINGS
	  	9
	 8
	  	 REPRESENTATIONS AND WARRANTIES
	  	11
	 9
	  	 POWERS AND DISCRETIONS OF THE LENDER
	  	12
	 10
	  	 WHEN SECURITY BECOMES ENFORCEABLE
	  	12
	 11
	  	 ENFORCEMENT OF SECURITY
	  	13
	 12
	  	 APPOINTMENT AND REMOVAL OF RECEIVER
	  	13
	 13
	  	 APPLICATION OF PROCEEDS
	  	17
	 14
	  	 NO LIABILITY AS MORTGAGEE IN POSSESSION
	  	17
	 15
	  	 PROTECTION OF THIRD PARTIES
	  	18
	 16
	  	 EXPENSES
	  	18
	 17
	  	 DELEGATION BY LENDER
	  	18
	 18
	  	 FURTHER ASSURANCES
	  	18
	 19
	  	 REDEMPTION OF PRIOR SECURITY INTERESTS
	  	19
	 20
	  	 POWER OF ATTORNEY
	  	19
	 21
	  	 SUBSEQUENT SECURITY INTERESTS AND NEW ACCOUNTS
	  	20
	 22
	  	 CONTINGENCIES
	  	21
	 23
	  	 COMBINATION AND SET-OFF
	  	21
	 24
	  	 CURRENCY
	  	21
	 25
	  	 CERTIFICATES AND DETERMINATIONS
	  	22
	 26
	  	 INDEMNITIES AND EXPENSES
	  	22
	 27
	  	 EFFECTIVENESS OF SECURITY
	  	24
	 28
	  	 REASSIGNMENT AND RELEASE OF SECURITY
	  	26
	 29
	  	 MISCELLANEOUS
	  	26
	 30
	  	 ASSIGNMENTS, TRANSFER, ETC
	  	27
	 31
	  	 NOTICES
	  	28
	 32
	  	 COUNTERPARTS
	  	28
	 33
	  	 NON-CONTRAVENTION
	  	28
	 34
	  	 AMENDMENT
	  	28
	 35
	  	 GOVERNING LAW
	  	28
	 36
	  	 ENFORCEMENT
	  	28
	 SCHEDULE 1 (Details of Insurances)
	  	28
	 SCHEDULE 2 (Form of Notice of Assignment)
	  	29
	 SCHEDULE 3 (Details of Data Centre Assets)
	  	33

  

 ii 

 THIS DEED is dated 27 June 2008 
 BETWEEN 
  

	 	(1)	SAVVIS UK LIMITED, a private limited company incorporated under the laws of England and Wales with registered number 03816299 whose registered office is at Eskdale Road,
Winnersh Triangle, Wokingham, Berkshire RG41 5TS (the “Borrower”); 

  

	 	(2)	SAVVIS, INC. a Delaware Corporation (“SAVVIS, Inc.”); and 

  

	 	(3)	LOMBARD NORTH CENTRAL PLC, a company incorporated under the laws of England and Wales with registered number 00337004 and having its registered office at 3 Princess Way,
Redhill RH1 1NP (the “Lender”). 

 RECITALS 
  

	 	(A)	The Lender has agreed to make available to the Borrower a term loan facility in an amount of up to £35,000,000 pursuant to, and in accordance with, the Facility Agreement.
SAVVIS, Inc. has agreed to guarantee the obligations of the Borrower under, inter alia, the Facility Agreement. 

  

	 	(B)	It is a condition precedent to the obligations of the Lender to make available the term loan facility to the Borrower under the Facility Agreement that, inter alia, the Borrower and
SAVVIS, Inc. enter into this Deed as security for their obligations under the Facility Agreement and other related documents. 

  

	 	(C)	The Borrower and SAVVIS, Inc. have agreed to enter into this Deed on the terms set out below. 

 OPERATIVE PROVISIONS 
  

	 	1	DEFINITIONS AND INTERPRETATION 

  

	 	1.1	Definitions 

 In this Deed, the following words and
expressions have the following meanings: 
 “Act” means the Law of Property Act 1925; 
 “Class A Data Centre Assets” means all those assets listed in Schedule 3 referred to as the Class A Assets and all other assets
from time to time acquired by the Borrower after the date hereof pursuant to the terms of the Construction Contracts and all replacements and substitutions thereto from time to time; 
 “Class B Data Centre Assets” means those assets listed in Schedule 3 referred to as the Class B Assets and all replacements and
substitutions thereto from time to time. 
 “Construction Contracts” has the meaning given to it in the Facility Agreement;

 “Data Centre Assets” means all of the Class A Data Centre Assets and the Class B Data Centre Assets; 
 “Data Centres” means the Docklands Data Centre, the Slough Data Centre and the Winnersh Data Centre; 
  

 1 

 “Default Rate” means, in relation to any amount not paid on its due date by the
Borrower, the rate specified in Clause 9.3.1 (Default Interest) of the Facility Agreement; 
 “Docklands Data Centre”
means the Borrower’s Data Centre at Greenwich View Place, Millharbour, London; 
 “Facility Agreement” means the
facility agreement dated 27 June 2008 and entered into by (1) the Borrower, (2) the Lender and (3) SAVVIS, Inc. as Guarantor, pursuant to which the Lender has agreed to make available a term loan facility in the maximum principal
amount of £35,000,000 to the Borrower; 
 “IA86” means the Insolvency Act 1986; 
 “Insurances” shall have the meaning given to it in the Facility Agreement which, as at the date hereof, are more particularly set out in
Schedule 1 hereto and, for the avoidance of doubt and for the purposes of this Deed shall not include any third party liability insurance or product liability insurance maintained by the Borrower or SAVVIS, Inc. or any proceeds arising therefrom;

 “Intercreditor Agreement” means an agreement dated on or about the date hereof between (1) the Lender;
(2) Wells Fargo Foothill Inc. (as agent) for all Senior Lenders and all Bank Product Providers (each as defined therein); and acknowledged by (1) SAVVIS Communications Corporation; (2) SAVVIS, Inc.; (3) SAVVIS Communications
International, Inc.; (4) SAVVIS Federal Systems Inc.; and (5) the Borrower to regulate, inter alia, their relevant security interests. 
 “Land” means the leasehold premises on which the Data Centres are situated; 
 “Location” means,
in respect of the Class A Data Centre Assets, the relevant location specified next to such Class A Data Centre Asset in Schedule 3; 
 “Notice of Assignment” means a notice of assignment in substantially the form set out in Schedule 2 (Form of Notice of Assignment) or in such other form as may be specified by the Lender; 
 “Permitted Security Interests” shall have the meaning given to it in the Facility Agreement; 
 “Receiver” means any one or more persons appointed as a receiver in accordance with the provisions of this Deed or the Act and includes
a receiver and manager and any similar or analogous person or persons as may be appointed pursuant to any insolvency legislation relevant to the Borrower or SAVVIS, Inc. in any jurisdiction; 
 “Second Lien” means all rights and interests held by any Senior Lender (as such term is defined in the Intercreditor Agreement) in and
to certain of the Insurances as subordinated to the rights of the Lender pursuant to the Intercreditor Agreement; 
 “Secured
Liabilities” means all monies, obligations and liabilities covenanted to be paid or discharged by the Borrower or SAVVIS, Inc. pursuant to the Finance Documents; 
 “Security” means the security from time to time constituted by, or pursuant to, this Deed; 
 “Security Assets” means the Data Centre Assets and the Insurances; 
 “Security Interest” shall
have the meaning given to it in the Facility Agreement; 
 “Security Period” shall have the meaning given to it in the
Facility Agreement; 
  

 2 

 “Slough Data Centre” means the Borrower’s Data Centre situated at 630 Ajax Road,
Slough, which at the date of this Deed, is under construction; 
 “Winnersh Data Centre” means the Borrower’s Data
Centre at Eskdale Road, Winnersh Triangle, Wokingham, Berkshire RG41 5TS. 
  

	 	1.2	Incorporation of the defined terms of the Facility Agreement 

 Words and expressions defined or construed in the Facility Agreement shall, unless otherwise defined herein, have, when used in this Deed, the same meanings in this Deed as in the Facility Agreement. 
  

	 	1.3	Construction 

  

	 	1.3.1	Unless a contrary indication appears, Clause 1.2 (Construction) of the Facility Agreement shall apply to this Deed. 

  

	 	1.3.2	References in this Deed to this “Deed” or any other deed, agreement or instrument are references to this Deed, the relevant deed, agreement or instrument as
amended, supplemented, replaced or novated from time to time and include references to any document which amends, supplements, replaces, novates or is entered into, made or given pursuant to, or in accordance with, this Deed, the relevant deed,
agreement or instrument. 

  

	 	1.3.3	Subject to Clause 12.2 (Powers of Receiver), references in this Deed to any regulation, statute or statutory provision are to be construed as references to the same as it may
have been, or may from time to time be, amended or re-enacted, and include references to all bylaws, instruments, orders and regulations for the time being made thereunder or deriving validity therefrom. 

  

	 	1.4	Law of Property (Miscellaneous Provisions) Act 1989 

 The terms of the Finance Documents and of any side letters between the parties thereto in relation to them are incorporated in this Deed to the extent required to ensure that any disposition of the Security Assets contained in this Deed is
a valid disposition in accordance with section 2(1) of the Law of Property (Miscellaneous Provisions) Act 1989. 
  

	 	1.5	Obligations 

 Any obligation of the Borrower or
SAVVIS, Inc. under this Deed to do something shall include an obligation to procure that it be done and any obligation not to do something shall include an obligation not to permit, suffer or allow it to be done. 
  

	 	1.6	Deed 

 It is intended by the parties hereto that
this document shall take effect as a deed, notwithstanding the fact that the Lender may only execute this document under hand. 
  

 3 

	 	1.7	Contracts (Rights of Third Parties) Act 1999 

 Unless expressly provided for, a person who is not a party to this Deed has no rights under the Contracts (Rights of Third Parties) Act 1999 to enforce or enjoy the benefit of any of the terms of this Deed. 
  

	 	1.8	Irrevocable payment 

 If the Lender considers that
an amount paid or discharged by, or on behalf of the Borrower or SAVVIS, Inc. by any other person in purported payment or discharge of an obligation of the Borrower or SAVVIS, Inc. to the Lender under the Finance Documents is capable of being
avoided or otherwise set aside on the liquidation or administration (or any analogous proceeding relevant to the Borrower or SAVVIS, Inc.) of either the Borrower or SAVVIS, Inc. or otherwise, then that amount shall be considered not to have been
unconditionally and irrevocably paid or discharged for the purposes of the Finance Documents. 
  

	 	1.9	The Lender and Receiver’s discretion 

 Any
liberty or power which may be exercised or any determination which may be made under this Deed by the Lender or any Receiver may be exercised or made in its absolute and unfettered discretion without any obligation to give reasons therefor.

  

	 	2	COVENANT TO PAY 

  

	 	2.1	Covenant to pay 

  

	 	2.1.1	The Borrower covenants with the Lender that it shall, on demand, pay and discharge the Secured Liabilities or it shall on demand procure that the Secured Liabilities are paid and
discharged when they are respectively due, in the manner provided in the relevant Finance Document. 

  

	 	2.2	Place 

 The Borrower shall procure that all
payments by the Borrower or SAVVIS, Inc. under or in respect of this Deed shall be made to the Lender and to its account at such office or bank as the Lender may notify to the Borrower from time to time for this purpose. 
  

	 	2.3	Funds 

 The Borrower shall procure that payments by
the Borrower or SAVVIS, Inc. under or in respect of this Deed to the Lender shall be made for value on the due date at such times and in such funds as the Lender may specify to the Borrower or SAVVIS, Inc. (as applicable) as being customary at the
time for the settlement of transactions of this nature in the relevant currency in the place of such payment. 
  

 4 

	 	2.4	Set-off and counterclaim 

 The Borrower shall
procure that all payments due from or made by the Borrower or SAVVIS, Inc. under or in respect of this Deed shall be made without set-off or counterclaim. 
  

	 	2.5	Non-Business Days 

 If a payment under this Deed is
due on a day which is not a Business Day, the due date for that payment shall instead be the next Business Day in the same calendar month (if there is one) or the preceding Business Day (if there is not). 
  

	 	2.6	Interest on Unpaid Sums 

 If either the Borrower or
SAVVIS, Inc. fails to pay any sum demanded of it under or in respect of this Deed, the Borrower shall pay an amount equal to interest on such Unpaid Sum (as well after as before judgment) at the Default Rate from the due date until the date on which
the Unpaid Sum is unconditionally and irrevocably paid or discharged in full to the Lender. 
  

	 	2.7	Time for payment of interest on Unpaid Sums 

 The
Borrower shall pay interest on an Unpaid Sum on demand. 
  

	 	2.8	Currency 

 Amounts payable in respect of costs,
expenses, Taxes and the like, and any amount payable under this Deed, are payable in sterling. 
  

	 	3	FIXED SECURITY 

  

	 	3.1	Grant of fixed security 

  

	 	3.1.1	The Borrower with full title guarantee, as security for the payment of all Secured Liabilities: 

  

	 	3.1.1.1	charges by way of a first fixed charge in favour of the Lender all of its rights, title and interest in and to the Class A Data Centre Assets owned by the Borrower at the date
of this Deed; 

  

	 	3.1.1.2	charges by way of a first fixed charge in favour of the Lender all of its rights, title and interest in and to the Class B Data Centre Assets owned by the Borrower at the date of
this Deed; and 

  

	 	3.1.1.3	charges by way of first fixed charge all replacements and substitutes for the Data Centre Assets that may be acquired by the Borrower after the date of this Deed and all Data Centre
Assets that may be acquired by the Borrower after the Date of this Deed in connection with the construction, design, installation, commissioning and fit out of the Slough Data Centre under the Construction Contracts. 

  

 5 

	 	3.1.2	Each of the Borrower and SAVVIS, Inc., with full title guarantee, as security for the payment of all Secured Liabilities, assigns by way of security to the Lender by way of first
ranking absolute assignment (in each case, subject to the proviso contained in Clause 3.2 (Proviso for reassignment)) all its right, title, benefit and interest in and to all proceeds of the Insurances to the extent that such proceeds arise in
connection with a loss, destruction or damage to the Data Centre Assets and all rights of the Borrower or SAVVIS, Inc. to enforce payment of the proceeds with respect to a loss, destruction or damage of the Data Centre Assets.

  

	 	3.1.3	The parties hereto agree that each Security Interest created by this Deed shall take effect as separate and independent first ranking fixed Security Interest.

  

	 	3.2	Proviso for reassignment 

 The assignment by the
Borrower and SAVVIS, Inc. in Clause 3.1.2 is subject to the proviso that, following the end of the Security Period, the Lender shall reassign to the Borrower or SAVVIS, Inc. (as applicable) or other person entitled thereto (without recourse or
warranty and at SAVVIS, Inc.’s expense), the subject-matter of that assignment or, as the case may be, the balance thereof. 
  

	 	4	DECLARATION OF TRUST 

  

	 	4.1	If, notwithstanding the provisions of Clause 3.1, any choses in action to which either the Borrower or SAVVIS, Inc. is entitled, are incapable of being, or for any reason are not
effectively, charged or assigned to the Lender in accordance with the terms of this Deed: 

  

	 	4.1.1	each of the Borrower and SAVVIS, Inc. declares that it holds and shall hold all its right, title and interest in and to the choses in action to which it is entitled on trust for the
Lender in accordance with the provisions of this Deed as if the same were effectively mortgaged or charged; 

  

	 	4.1.2	the Borrower shall use all reasonable endeavours promptly to bring about an effective assignment or charge of the choses in action in favour of the Lender; and

  

	 	4.1.3	for the avoidance of doubt, such choses in action shall nevertheless constitute Security Assets. 

  

	 	5	GENERAL UNDERTAKINGS 

  

	 	5.1	Duration 

 The undertakings in this Clause 5 to
Clause 7 inclusive are given in favour of the Lender and shall remain in force throughout the Security Period. 
  

 6 

	 	5.2	Nature of Security 

  

	 	5.2.1	The Borrower represents to the Lender that this Deed creates those Security Interests it purports to create, with the ranking set out in this Deed, and is not liable to be amended
or otherwise set aside on the liquidation or administration of the Borrower or any similar or analogous procedure relating to either the Borrower or SAVVIS, Inc. in any relevant jurisdiction or otherwise. 

  

	 	5.2.2	The Borrower represents to the Lender that neither it nor SAVVIS, Inc. has created or purported to create, nor will it or SAVVIS, Inc. create during the Security Period, any
floating charge(s) over any of the Security Assets, save for the Second Lien. 

  

	 	5.3	Dealing with Security Assets 

 Save for the Second
Lien, and except as expressly permitted by Clause 7 hereto, and, subject to Clause 5.5 (Notices received relating to Security Assets), the Borrower shall not and the Borrower shall procure that SAVVIS, Inc. shall not, without the prior
written consent of the Lender: 
  

	 	5.3.1	sell, transfer, grant any lease or licence in relation to, enter into any agreement for the sale, transfer of, grant of lease or licence relating to, or otherwise dispose of, the
Security Assets; 

  

	 	5.3.2	part with possession of the Security Assets; or 

  

	 	5.3.3	enter into any option agreement or arrangement having a similar effect to any of the actions referred to above in this Clause 5.3. 

  

	 	5.4	No Security Interest over Security Assets 

 The
Borrower shall not and the Borrower shall procure that SAVVIS, Inc. shall not create or allow to submit any Security Interest on or over the Security Assets, save for any Permitted Security Interest and the Second Lien. 
  

	 	5.5	Notices received relating to Security Assets 

 The
Borrower shall and the Borrower shall procure that SAVVIS, Inc. shall, as soon as reasonably practicable following receipt, give to the Lender a copy of any notice, order, direction, requisition, permission, proposal or other matter (a
“Direction”) received by the Borrower or SAVVIS, Inc. affecting or likely to affect the Security Assets in a manner which is reasonably likely to have a Material Adverse Effect. 
  

	 	5.6	Action following receipt of notice under Clause 5.5 (Notices received relating to Security Assets) 

 Following the giving of the copy Direction referred to in Clause 5.5 (Notices received relating to Security Assets): 
  

	 	5.6.1	the Borrower shall and shall procure that the Lender shall, at the request of the Lender, but at the Borrower’s cost, make or join with the Lender in making such objections or
representations against or in respect of that Direction as the Lender (acting reasonably) shall deem necessary or expedient; 

  

 7 

	 	5.6.2	the Borrower shall and shall procure that SAVVIS, Inc. shall, as soon as practicable following the request of the Lender (acting reasonably), take all reasonable steps to comply
with that Direction, unless the Borrower or SAVVIS, Inc., as appropriate, is contesting that Direction in good faith; and 

  

	 	5.6.3	subject to Clause 5.6.2, the Lender may, without incurring any of the liabilities of a mortgagee in possession, upon giving the Borrower 5 (five) Business Days prior written notice,
enter upon the Data Centres for the purpose of complying with any Direction and may itself, at the cost of the Borrower, do all acts and things reasonably necessary or proper for complying with any of them. 

  

	 	5.7	Taxes 

 The Borrower shall and shall procure that
SAVVIS, Inc. shall: 
  

	 	5.7.1	punctually pay all taxes, charges, duties, levies, assessments, impositions and outgoings whatsoever (whether governmental, municipal or otherwise) which may be imposed upon, or
payable in respect of, the Security Assets unless such payment is being disputed in good faith by the Borrower or SAVVIS, Inc. (as applicable); and 

  

	 	5.7.2	on demand of the Lender, produce to the Lender receipts confirming, or other evidence of, such payment described in Clause 5.7.1 or, if the payment is in dispute, evidence of such
dispute and, immediately upon resolution of such dispute, evidence of the resolution. 

  

	 	6	INSURANCE UNDERTAKINGS 

  

	 	6.1	Insurance 

 The Borrower shall, in addition to the
requirements set out in this Clause 6, procure that all of the Data Centre Assets as are of an insurable nature are insured and kept insured in accordance with Clause 29 (Insurance Undertakings) of the Facility Agreement. 
  

	 	6.2	Perfection of Security 

  

	 	6.2.1	On or before the date of this Deed, the Borrower shall deliver (or shall procure that there is delivered) a notice to the relevant Approved Broker in respect of the Insurances
specified in Schedule 1 Part III (Details of Insurances) in substantially the form of Schedule 2 (Form of Notice of Assignment) (or as otherwise required by the Lender) and shall procure that each such Approved Broker acknowledges,
agrees and confirms such notice to the Lender. 

  

 8 

	 	7	DATA CENTRE ASSETS UNDERTAKINGS 

  

	 	7.1	Location of Data Centre Assets 

  

	 	7.1.1	Subject to Clauses 7.1.2 and 7.3, the Borrower shall keep the Class A Data Centre Assets listed in Schedule 3 (Details of Data Centre Assets) at the location specified
for those Class A Data Centre Assets in Schedule 3 (Details of Data Centre Assets). 

  

	 	7.1.2	Notwithstanding Clause 7.1 above, the Borrower may remove any Data Centre Asset from its location specified in Clause 7.1 (Location of Data Centre Assets) solely for the
purpose and in the course of effecting necessary repairs to it, but only to another location previously notified in writing to the Lender. In no circumstances may the Borrower, without the prior written consent of the Lender, remove any Class A
Data Centre Asset to a location outside England and Wales. 

  

	 	7.2	Repair and Maintenance of Data Centre Assets and Access 

  

	 	7.2.1	The Borrower shall keep and maintain the Data Centre Assets in a good and safe condition and state of repair, and shall repair such Data Centre Assets as necessary, to no less an
extent than would a reasonably prudent owner and operator of assets, similar to the Data Centre Assets (acting in accordance with and having full regard to (i) any suppliers’ and/or manufacturers’ recommendations and (ii) normal
industry practice, standards and requirements applicable to assets, similar to the Data Centre Assets). 

  

	 	7.2.2	Provided that the Lender has given the Borrower 5 (five) Business Days prior written notice of its intention to do so, permit the Lender and its agents and servants, with or without
workmen, from time to time to examine the state and condition of any of the Data Centre Assets. 

  

	 	7.3	Removal and Disposal of Data Centre Assets 

  

	 	7.3.1	The Data Centre Assets may be moved from one Data Centre to another, as may be reasonably required by the Borrower from time to time, provided that the Borrower shall, upon
reasonable written request from the Lender, provide the Lender with written details specifying the location of each of the Class A Data Centre Assets. 

  

	 	7.3.2	Save as set out in Clause 7.1.2 and this Clause 7.3, the Borrower may not remove the Class A Data Centre Assets from the Location or dispose of them for any reason, without the
prior written consent of the Lender. 

  

	 	7.3.3	In addition to its rights under Clauses 7.1.2 and 7.3.1, the Borrower may remove and sell such of the Class B Data Centre Assets, that are no longer required for use at any of the
Data Centres or for any reason or have become obsolete, provided that the aggregate value of all such Class B Data Centre Assets (valued as at the date of disposal) to be disposed of from time to time, does not exceed a maximum aggregate amount of
£2,000,000 (two million pounds Sterling) from the date hereof until the Termination Date, or other termination of the Facility Agreement in accordance with its terms. 

  

 9 

	 	7.3.4	At the Lender’s request, which request may be made no more frequently than once per annum during the Commercial Loan Period, the Borrower will provide the Lender with such
information as the Lender may reasonably request in order to enable the Lender to determine to its satisfaction the value of the Class B Assets disposed of by the Borrower from time to time. 

  

	 	7.3.5	If the Lender, at is absolute discretion, agrees that any of the Class A Data Centre Assets may be sold, it shall agree the terms of such sale with the Borrower and direct that
the sales proceeds received are either use to make a pre-payment of the Loan(s) in accordance with Clause 8.2 of the Facility Agreement or to acquire replacement Class A Data Centre Assets. 

  

	 	7.4	Replacements and subsequently acquired Data Centre Assets 

  

	 	7.4.1	Any replacements or substitutes of any Data Centre Assets which the Borrower is entitled to make in accordance with this Agreement shall be the same type of asset and similar value
as that asset being replaced. 

  

	 	7.4.2	The Borrower agrees that any replacement for or substitute of any Data Centre Assets shall be Security Assets and subject to the terms of this Deed, and shall be deemed to be either
Class A Data Centre Assets or Class B Data Centre Assets, as the parties hereto may decide, and Class A Data Centre Assets acquired by the Borrower after the date hereof shall be subject to the terms of this Deed and the Borrower agrees
that it shall do all such assurances, acts and things as the Lender may reasonably require for perfecting the Lender’s Security Interests in such Data Centre Assets in accordance with Clause 18 of this Deed and the Borrower undertakes that it
shall provide the Lender with: (i) a schedule of all Class A Data Centre Assets acquired by the Borrower after the date hereof on or before the date of acquisition; and (ii) a schedule of all replacement and substitute Class A
Data Centre Assets acquired by the borrower from time to time, as permitted by the terms of this Deed of the Facility Agreement, as soon as reasonably practicable following acquisition. 

  

	 	7.4.3	Save as the Lender may otherwise agree, in its absolute discretion, the Borrower may only replace Class A Data Centre Assets in accordance with Clauses 8.2.1.2 and 29.5.1 of
the Facility Agreement. 

  

	 	7.5	Insurance 

 Without prejudice to the generality of
Clause 6 (Insurance Undertakings), the Borrower or SAVVIS, Inc. shall insure the Data Centre Assets in accordance with Clause 6 (Insurance Undertakings). 
  

 10 

	 	7.6	Negative covenants 

  

	 	7.6.1	The Borrower shall ensure that: 

  

	 	(a)	nothing is done or omitted to be done which is likely to result in the Data Centre Assets being confiscated, seized, requisitioned, taken in execution, impounded or otherwise taken
from any of the Data Centres and, in any such event, the Borrower will procure an immediate release of the Data Centre Assets; 

  

	 	(b)	none of the Data Centre Assets is removed from any of the Data Centres save in accordance with this Deed and the Facility Agreement; 

  

	 	(c)	none of the Data Centre Assets is altered, interfered with or materially attached to any machinery or plant or any other equipment, and no plant, machinery or accessories are
attached to the Data Centre Assets which cannot be removed without damaging or impairing such Data Centre Assets except as may be required for the normal operation of such Data Centre Assets, provided that the Borrower shall indemnify the Lender for
any loss, costs, claims or damages the Lender suffers sustains or incurs as a result of: (i) the Lender’s inability to recover any Data Centre Asset as a result of its having been attached to any other plant or machinery; or (ii) the
Lender being required to make good any damage to any Data Centre Asset or any plant or machinery to which it may have been attached; and 

  

	 	(d)	the Data Centre Assets are not used for any unlawful purposes. 

  

	 	8	REPRESENTATIONS AND WARRANTIES 

  

	 	8.1	Nature and timing 

 In addition to the
representations and warranties set out in Clause 22 of the Facility Agreement, the representations and warranties set out in this Clause 8 are made in favour of the Lender with the knowledge and intention that the Lender is relying on and shall rely
on them throughout the Security Period. 
  

	 	8.2	Security ranking 

 The Borrower represents and
warrants that this Deed: 
  

	 	8.2.1	constitutes, and shall, throughout the Security Period, constitute, legal, valid, binding and enforceable obligations of the Borrower and SAVVIS, Inc., subject to any general
principles of law limiting its obligations which are specifically referred to in any legal opinion delivered pursuant to any Finance Documents; 

  

	 	8.2.2	has and shall, throughout the Security Period, have the ranking of a first fixed charge and first priority assignment over the Security Assets effective in accordance with its
terms. 

  

 11 

	 	8.3	Consents 

 The Borrower represents and warrants
that all actions, conditions and things required to be taken, fulfilled and done (including the obtaining of any necessary consents or the like) in order to enable the Borrower and SAVVIS, Inc. to create this Security and to ensure that (subject to
all necessary registrations thereof being made) this Security is valid, legally binding and enforceable and has and will have the ranking referred to in Clause 8.2 (Security ranking) have been taken, fulfilled and done. 
  

	 	9	POWERS AND DISCRETIONS OF THE LENDER 

  

	 	9.1	Curing of breaches and covenants 

 Without
prejudice to the rights of the Lender under the Finance Documents, if either the Borrower or SAVVIS, Inc. fails to observe or perform any provision of this Deed and such failure is not remedied to the satisfaction of the Lender within 15 Business
Days, the Borrower and SAVVIS, Inc. shall allow and hereby authorise the Lender or such person as the Lender shall nominate to do all such acts and things and take such action on behalf of the Borrower and SAVVIS, Inc. as may be necessary to secure
the observance or performance of that provision without becoming liable as a mortgagee in possession, provided that such action is permitted to be undertaken by the Lender under the terms of the Intercreditor Agreement. 
  

	 	9.2	Indemnity 

 The Borrower shall indemnify the Lender
and keep the Lender indemnified against all reasonable losses, costs, charges and expenses properly incurred by the Lender as a result of the failure by the Borrower or SAVVIS, Inc. to observe or perform any provision of this Deed and in connection
with the exercise by the Lender of its rights contained in Clause 9.1 (Curing of breaches and covenants). 
  

	 	9.3	Expenses so incurred 

 All monies reasonably and
properly expended and all costs reasonably and properly incurred by the Lender in carrying out any of its powers and discretions referred to in Clause 9.1 (Curing of breaches and covenants) shall be considered to have been properly incurred
by the Lender, shall be secured by this Deed and shall be payable on demand by the Borrower to the Lender. 
  

	 	10	WHEN SECURITY BECOMES ENFORCEABLE 

  

	 	10.1	Timing of enforcement 

  

	 	10.1.1	The security intended to be created by this Deed shall become immediately enforceable upon the occurrence of an Event of Default which (as at the date of the first steps of
enforcement) is continuing and has not been remedied or waived. 

  

	 	10.1.2	After the security intended to be created by this Deed has become enforceable: 

  

	 	10.1.2.1	the power of sale and other powers conferred by Section 101 of the Act (as varied or amended by this Deed) shall become immediately exercisable; 

  

 12 

	 	10.1.2.2	the Lender may, in its absolute discretion, enforce all or any part of such security in such manner as it sees fit; and 

  

	 	10.1.2.3	the Borrower shall or shall procure that the Lender is granted access to the Location in order to take possession of and, where it requires to do so, remove the Data Centre Assets.

  

	 	11	ENFORCEMENT OF SECURITY 

  

	 	11.1	Powers arising 

 The Secured Liabilities shall be
deemed to have become due and payable, and the power of sale and other powers conferred on mortgagees by section 101 of the Act as varied and extended by this Deed, shall arise immediately on execution of this Deed by the Borrower and SAVVIS, Inc.

  

	 	11.2	Powers exercisable 

 Neither section 93 nor section
103 of the Act shall apply to this Deed and the powers referred to in Clause 11.1 (Powers arising) may be exercised by the Lender and this Security shall become enforceable without notice to the Borrower or SAVVIS, Inc. on or at any time
after an Event of Default has occurred. 
  

	 	12	APPOINTMENT AND REMOVAL OF RECEIVER 

 The rights of
the Lender under this Clause are subject to the terms of the Intercreditor Agreement. 
  

	 	12.1	Appointment of Receiver 

  

	 	12.1.1	At any time after this security becomes enforceable or if either the Borrower or SAVVIS, Inc. so requests the Lender in writing at any time, the Lender may without further notice
appoint, under seal or in writing under its hand, any one or more qualified persons to be a Receiver of all or any part of the Security Assets in like manner in every respect as if the Lender had become entitled under the Act to exercise the power
of sale thereby conferred. In this Clause “qualified person” means a person who, under IA86, or any similar or analogous legislation relevant to the Borrower or SAVVIS, Inc. in any jurisdiction, is qualified to act as a receiver (or
similar or analogous person) of the property of any company with respect to which he is appointed. 

  

	 	12.1.2	Where any appointment of a Receiver is made at a time when a Receiver is already in and continues in office, the Receiver shall act jointly with the Receiver previously appointed
hereunder. 

  

 13 

	 	12.1.3	Every such appointment of a Receiver shall take effect at the time and in the manner specified by IA86, or any similar or analogous legislation relevant to either the Borrower or
SAVVIS, Inc. in any jurisdiction. 

  

	 	12.1.4	If at any time any two or more persons hold office as Receivers of the same assets or income, such Receivers may act jointly or concurrently so that each of such Receivers shall be
entitled (unless the contrary shall be stated in any of the instrument(s) appointing them) to exercise all the functions conferred on a Receiver by IA86 ( or any similar or analogous legislation relevant to either the Borrower or SAVVIS, Inc. in any
jurisdiction) or the Act and in this Deed. 

  

	 	12.2	Powers of Receiver 

  

	 	12.2.1	Every Receiver appointed in accordance with Clause 12.1 (Appointment of Receiver) shall have and be entitled to exercise, in addition to those powers conferred by the Act on
any receiver appointed thereunder: 

  

	 	12.2.1.1	all of the powers set out in Clause 12.3 (Specific powers); and 

  

	 	12.2.1.2	any and all powers, authorities and rights, in relation to the Security Assets, which it could exercise if it were the absolute unencumbered beneficial owner of such Security
Assets. 

  

	 	12.2.2	If at any time there is more than one Receiver of all or any part of the Security Assets, each such Receiver may (unless otherwise stated in any document appointing him) exercise
all of the powers conferred on a Receiver under this Deed individually and to the exclusion of each other Receiver. 

  

	 	12.2.3	Any Receiver may, in its absolute discretion, choose whether, and if so when, or not to exercise any of such powers, and the Borrowers and SAVVIS, Inc. recognise that the Receiver
may do so notwithstanding that the same may be prejudicial to its interests and in this respect the Borrower hereby waives to the fullest extent permissible any rights it may otherwise have under section 91(2) of the Act. 

 

	 	12.3	Specific powers 

  

	 	12.3.1	The powers referred to in the first sentence of Clause 12.2 (Power of Receiver) include: 

  

	 	12.3.1.1	Take possession: to take immediate possession of, get in and collect the Security Assets or any part thereof; 

  

	 	12.3.1.2	Carry on Business: to carry on the business of the Borrower as he may think fit; 

  

 14 

	 	12.3.1.3	Protection of assets: to make and effect all repairs and insurances and do all other acts for the protection or for the improvement of the Security Assets as he may in his
absolute discretion think fit; 

  

	 	12.3.1.4	Employees: to appoint and discharge managers, officers, agents, accountants, servants, workmen and others for the purposes hereof upon such terms as to remuneration or
otherwise as he may think proper and to discharge any such persons appointed by the Borrower; 

  

	 	12.3.1.5	Borrow money: for the purpose of exercising any of the powers, authorities and discretions conferred on him by or pursuant to this Deed and/or of defraying any costs,
charges, losses or expenses (including his remuneration) which shall be incurred by him in the exercise thereof or for any other purpose, to raise and borrow money either unsecured or on the security of the Security Assets or any part thereof,
either in priority to the security constituted by this Deed or otherwise, and generally on such terms and conditions as he may think fit and no person lending such money shall be concerned to enquire as to the propriety or purpose of the exercise of
such power or to see to the application of any money so raised or borrowed; 

  

	 	12.3.1.6	Sell assets: to sell, exchange, convert into money and realise or otherwise howsoever dispose of all or any part of the Security Assets by public auction or private contract
and generally in such manner and on such terms as he shall think proper. Without prejudice to the generality of the foregoing he may do any of these things for a consideration or for a nil consideration consisting of cash, debentures or other
obligations, shares, stock or other valuable consideration and any such consideration may be payable in a lump sum or by instalments spread over such period as he may think fit. Any such sale, exchange, conversion or realisation and disposal may be
on terms excluding or restricting the liability of the Lender or the Receiver; 

  

	 	12.3.1.7	Leases: to let or licence all or any part of the Security Assets for such term and at such rent or licence fee (with or without a premium) as he may think proper and to vary
and/or accept a surrender of any lease or licence thereof on such terms as he may think fit (including the payment of money to a lessee or licensee on a surrender) and so that for the purposes of Section 99(2) of the Act the expression
“mortgagor” shall include an encumbrancer deriving title under the Borrower; 

  

	 	12.3.1.8	Compromise: to settle, adjust, refer to arbitration, compromise and arrange any claims, accounts, disputes, questions and demands with or by any person who is or claims to be
a creditor of the Borrower or SAVVIS, Inc. or relating in any way to the Security Assets or any part thereof; 

  

	 	12.3.1.9	Legal actions: to bring, prosecute, enforce, defend and abandon all such actions, suits and proceedings in relation to the Security Assets or any part thereof as may seem to
him to be expedient; 

  

 15 

	 	12.3.1.10	Receipts: to give valid receipts for all moneys and execute all assurances and things which may be proper or desirable for realising the Security Assets;

  

	 	12.3.1.11	Subsidiaries: to form a subsidiary or subsidiaries of the Borrower and transfer to any such subsidiary all or any part of the Security Assets; 

  

	 	12.3.1.12	Registered office: to change the registered office of the Borrower; 

  

	 	12.3.1.13	Contracts: to enter into, perform, repudiate, rescind, vary, modify, assign or novate any contract, agreement option, agreement, building contract, professional appointment
or otherwise for or which relates in any way to the Security Assets or any part thereof or in relation to the exercise of any of the powers of the receiver herein contained and to appoint hire and employ and to remunerate such contractors, advisers,
professionals, agents, servants, attendants, managers, officers, workmen and others upon such terms and at such salaries, fees or remuneration and generally in such manner as he shall think fit and to discharge any such persons;

  

	 	12.3.1.14	Proceedings: to take any proceedings whether in the name of the Borrower or SAVVIS, Inc. (or either of them) or otherwise as the Receiver may think fit and whether relating
to any of the matters herein contained or otherwise and to make any arrangement or compromise which he may think expedient; 

  

	 	12.3.1.15	Indemnity: to take any indemnity from the Borrower or SAVVIS, Inc. from and against all actions, claims, expenses, demands and liabilities whether arising out of the contract
or out of tort or in any other way incurred by him or by any manager, agent, officer, servant or workman or other person for whose debt, default or miscarriage he may be answerable for anything done or omitted to be done in the exercise or purported
exercise of his powers hereunder or under any appointment duly made under the provisions of this Clause and if he thinks fit, but without prejudice to the foregoing, to effect with any insurance company or office or underwriters any policy or
policies of insurance either in lieu or satisfaction of or in addition to such indemnity from the Borrower or SAVVIS, Inc.; and 

  

	 	12.3.1.16	General powers: to do all such other acts and things as he may consider desirable or necessary for realising the Security Assets or any part thereof or incidental or
conducive to any of the matters, powers or authorities conferred on a Receiver under or by virtue of this Deed, to exercise in relation to the Security Assets or any part thereof all such powers, authorities and things as he would be capable of
exercising if he were the absolute beneficial owner of the same and to use the name of the Borrower for all or any of such purposes. 

  

	 	12.4	Removal and remuneration 

 The Lender may from time
to time, by writing under its hand, remove any Receiver appointed by it and may, whenever it may deem it expedient, appoint a new Receiver in the place of any Receiver whose appointment may for any reason have terminated, and may from time to time
fix the remuneration of any Receiver appointed by it. 
  

 16 

	 	12.5	Lender may exercise 

 To the fullest extent
permitted by law, all or any of the powers, authorities and discretions which are conferred by this Deed (either expressly or implied) upon a Receiver of the Security Assets may be exercised after the security hereby created becomes enforceable by
the Lender, in relation to the whole of such Security Assets or any part thereof, without first appointing a Receiver of such property or any part thereof or notwithstanding the appointment of a Receiver of such property or any part thereof.

  

	 	13	APPLICATION OF PROCEEDS 

 Any moneys received by
the Lender or by any Receiver appointed by it pursuant to this Deed and/or under the powers hereby conferred shall, after the security hereby constituted shall have become enforceable, but subject to the payment of any claims having priority to this
security, be applied by the Lender, unless otherwise determined by the Lender or such Receiver, in accordance with Clause 33.2 of the Facility Agreement (but without prejudice to the right of the Lender to recover any shortfall from the Borrower).

  

	 	14	NO LIABILITY AS MORTGAGEE IN POSSESSION 

  

	 	14.1	No mortgagee in possession 

 Neither the Lender nor
any Receiver shall, by reason of either entering into possession of the Security Assets, be liable to account as mortgagee in possession or be liable for any loss on realisation or for any default or omission for which a mortgagee in possession
might be liable except to the extent caused by the gross negligence or wilful misconduct of the Lender or any Receiver. 
  

	 	14.2	Receiver as agent 

 Each Receiver shall be deemed
to be the agent of the Borrower and SAVVIS, Inc. for all purposes and in the same position as a receiver duly appointed by a mortgagee under the Act or under any similar or analogous legislation relevant to either the Borrower or SAVVIS, Inc. in any
jurisdiction. The Borrower or SAVVIS, Inc. (as applicable) alone shall be responsible for the Receiver’s contracts, engagements, acts, omissions, defaults for losses and liabilities incurred by him and the Lender shall not incur any liability
therefor to either of the Borrower or SAVVIS, Inc. or any other person whatsoever by reason of the Lender’s appointing him as Receiver or for any other reason whatsoever. 
  

	 	14.3	Rights, powers, privileges and immunities by the Act 

 Each Receiver and the Lender shall be entitled to all the rights, powers, privileges and immunities by the Act conferred on mortgagees and receivers when such receivers have been duly appointed under the Act but so that section 103 of the
Act shall not apply. 
  

 17 

	 	15	PROTECTION OF THIRD PARTIES 

 No purchaser,
mortgagee or other person or company, with the exception of the Lender, dealing with the Lender or the Receiver or its or his agents shall be concerned to enquire whether the Secured Liabilities have become payable or whether any power which the
Lender or the Receiver is purporting to exercise has become exercisable or whether any of the Secured Liabilities remain outstanding or to see to the application of any money paid to the Lender or to such Receiver. 
  

	 	16	EXPENSES 

 All costs, charges and expenses
reasonably and properly incurred and all payments made by the Lender or any Receiver appointed hereunder in the lawful exercise of the powers hereby conferred, whether or not occasioned by any act, neglect or default of the Borrower or SAVVIS, Inc.,
shall carry interest (as well after as before judgment) at the relevant Default Rate from the date of the same being incurred or becoming payable until the date the same are unconditionally and irrevocably paid and discharged in full. The amount of
all such costs, charges, expenses and payments and all such interest thereon and all remuneration payable hereunder shall be payable by the Borrower within three Business Days of demand. All such costs, charges, expenses and payments shall be
secured by the Security and shall be paid and charged as between the Lender and the Borrower on the basis of a full indemnity. 
  

	 	17	DELEGATION BY LENDER 

 The Lender may at any time
and from time to time delegate by power of attorney, or in any other manner, to any person or persons, all or any of the powers, authorities and discretions which are for the time being exercisable by the Lender under this Deed in relation to the
Security Assets or any part thereof. Any such delegation may be made upon such terms (including the power to sub-delegate) and subject to such regulations as the Lender may think fit. The Lender shall not be in any way liable or responsible to
either the Borrower or SAVVIS, Inc. for any loss or damage arising from any act, default, omission or misconduct on the part of any such delegate or sub-delegate except to the extent caused by fraud, gross negligence or wilful misconduct of the
Lender. 
  

	 	18	FURTHER ASSURANCES 

  

	 	18.1	Perfection of Security Interests 

 The Borrower
shall, at its own expense, execute and do or procure that there are executed and done all such assurances, acts and things as the Lender may reasonably require for perfecting the Security Interests intended to be created by this Deed over the
Security Assets or for facilitating the realisation of the Security Assets and in the exercise of all powers, authorities and discretions vested in the Lender or any Receiver of the Security Assets or in any delegate or sub-delegate. 
  

	 	18.2	Specific acts 

 Each of the Borrower and SAVVIS,
Inc. shall, in particular but without limitation, execute all transfers, conveyances, assignments and assurances of the Security Assets whether to the Lender or to its nominees and give all notices, orders and directions and make all registrations
which the Lender may (acting reasonably) think expedient, provided that such action is permitted to be undertaken by the Lender under the terms of the Intercreditor Agreement. 
  

 18 

	 	18.3	Fixed Security Interests 

 Without prejudice to
Clause 18.2 (Specific acts), the Borrower or SAVVIS, Inc. (as applicable) shall forthwith, at the request of the Lender, execute a legal charge or assignment over those Security Assets subject to or intended to be subject to any fixed
security created by this Deed in favour of the Lender, in such form as the Lender may require incorporating provisions similar to this Deed, with such amendments as the Lender may require, having regard to the nature of the asset, the Security
Interest to be created and any change in law. 
  

	 	18.4	Notices of this Security 

 The Borrower shall
promptly affix to the Security Assets, and indorse or cause to be indorsed or shall procure that these are affixed or indorsed on the certificates and documents which constitute or evidence title to the Security Assets, such notices, endorsements or
memoranda referring to this Security as the Lender may reasonably and from time to time require. 
  

	 	19	REDEMPTION OF PRIOR SECURITY INTERESTS 

  

	 	19.1	Redemption of Security Interests 

 The Lender may,
at any time after the security hereby constituted has become enforceable, redeem any prior Security Interests against the Security Assets or any part thereof or procure the transfer thereof to itself and may settle and pass the accounts of the prior
mortgagee, chargee or encumbrancer. 
  

	 	19.2	Accounts conclusive 

 Any accounts so settled and
passed shall be conclusive and binding on the Borrower except in the case of manifest error. 
  

	 	19.3	Borrower to pay on demand 

 All principal moneys,
interest, costs, charges and expenses of and incidental to such redemption and transfer reasonably and properly incurred shall be paid by the Borrower to the Lender on demand. 
  

	 	20	POWER OF ATTORNEY 

  

	 	20.1	Appointment 

 Each of the Borrower and SAVVIS, Inc.
hereby, by way of security and in order more fully to secure the performance of its obligations under this Deed or the Facility Agreement, irrevocably appoints the Lender and every delegate or sub-delegate to be their attorney acting severally, and
on its behalf and in its name or otherwise: 
  

 19 

	 	20.1.1	to execute and do all such assurances, acts and things which the Borrower or SAVVIS, Inc. (as applicable) ought to do under this Deed and the Facility Agreement;

  

	 	20.1.2	to make any demand upon, or to give any notice or receipt to, any person owing monies to the Borrower or SAVVIS, Inc. (as applicable) provided that such action is permitted to be
undertaken under the terms of the Intercreditor Agreement; 

  

	 	20.1.3	to execute and deliver any legal charges, assignments or other security and any transfers of shares, bonds or similar securities; 

  

	 	20.1.4	to exercise the powers, authorities and discretions conferred by or pursuant to this Deed or by statute on the Lender or any such Receiver, delegate or sub-delegate; and

  

	 	20.1.5	to sell and deliver and otherwise perfect any deed, assurance, agreement, instrument or act which it may deem proper in or for the purpose of exercising any of such powers,
authorities and discretions. 

  

	 	20.2	Ratification 

 Each of the Borrower and SAVVIS,
Inc. hereby ratifies and confirms and agrees to ratify and confirm whatever any such attorney as is mentioned in this Clause 20 shall do or purport to do in the exercise or purported exercise of all or any of the powers, authorities and discretions
referred to in this Clause. 
  

	 	20.3	General power 

 The appointment under Clause 20.1
(Appointment) shall operate as a general power of attorney made under section 10 of the Powers of Attorney Act 1971. 
  

	 	21	SUBSEQUENT SECURITY INTERESTS AND NEW ACCOUNTS 

 If
the Lender shall at any time receive or be deemed to have received notice of any Security Interest affecting the Security Assets or any assignment or transfer thereof which is prohibited by this Deed: 
  

	 	21.1	the Lender may open a new account for the Borrower and/or SAVVIS, Inc. in its books; and 

  

	 	21.2	if the Lender does not in fact open such new account, then, unless it gives express written notice to the Borrower or SAVVIS, Inc. to the contrary, it shall be treated as if it had
in fact opened such account at the time when it received or was deemed to have received such notice, 

 and as from such time
and unless such express written notice shall be given to the Borrower or SAVVIS, Inc., all payments by or on behalf of the Borrower and SAVVIS, Inc. to the Lender shall be credited or treated as having been credited to such new account and not as
having been applied in reduction of the Secured Liabilities at such time. 
  

 20 

	 	22	CONTINGENCIES 

 If the Security is enforced at a
time when no amount is due under the Finance Documents but at a time when amounts may or will become due, the Lender (or the Receiver) may pay the proceeds of any recoveries effected by it unto a suspense account. Any proceeds paid into a suspense
account must be applied by the Lender in payment of amounts due under the Finance Documents as and when those amounts become due. 
  

	 	23	COMBINATION AND SET-OFF 

  

	 	23.1	Combination 

 The Lender may without notice to the
Borrower combine, consolidate or merge all or any of the accounts of the Borrower with, and liabilities to, the Lender (including, without limitation, under any hedging or other agreement made between the Lender and the Borrower. 
  

	 	23.2	Set-off 

 The Lender may set-off any matured
obligation due from either of the Borrower or SAVVIS, Inc. under this Deed against any matured obligation owed by the Lender to either the Borrower or SAVVIS, Inc., regardless of the place of payment, booking branch or the currency of either
obligation. If the obligations are in different currencies, the Lender may convert either obligation at a market rate of exchange in its usual course of business for the purpose of the set-off, provided that such action is permitted to be undertaken
by the Lender under the Intercreditor Agreement. 
  

	 	23.3	Notice 

 The Lender shall notify the Borrower or
SAVVIS, Inc. (as applicable) immediately on the exercise or purported exercise of any right under this Clause 23 provided that any failure by the Lender so to notify will not invalidate or otherwise prejudice any such exercise or purported exercise.

  

	 	24	CURRENCY 

  

	 	24.1	Currency Conversion 

 The Lender may, in connection
with any application of any monies pursuant to this Deed and whether for the purpose of or pending the discharge of the Secured Liabilities, convert any monies from time to time in accordance with Clause 17.1 of the Facility Agreement. 

 

 21 

	 	24.2	Currency indemnity 

 The Borrower shall indemnify
the Lender in accordance with Clause 17.1 of the Facility Agreement for any sum due in relation to any currency conversion performed pursuant to Clause 24.1 (Currency conversion). 
  

	 	25	CERTIFICATES AND DETERMINATIONS 

 Any certification
or determination by the Lender of a rate or amount under this Deed is, in the absence of manifest error, conclusive evidence of the matters to which it relates. 
  

	 	26	INDEMNITIES AND EXPENSES 

  

	 	26.1	General indemnity 

 The Borrower shall, on demand,
indemnify the Lender, any Receiver and any manager, agent, officer or employee for whose liability, acts or omissions the Lender or the Receiver may be answerable from and against all liabilities, costs, charges, losses, expenses, legal and other
professional fees (including Tax) suffered or incurred by any of them, except by their own gross negligence or wilful misconduct, arising from or as a result of: 
  

	 	26.1.1	the exercise or the purported exercise of any powers, authorities or discretions conferred on any of them under or by virtue of this Deed; 

  

	 	26.1.2	any matter or thing done or omitted to be done under, or in any way relating to, this Deed; 

  

	 	26.1.3	any breach, non-observance or non-performance by the Borrower or SAVVIS, Inc. of any of its covenants, undertakings, obligations, representations or warranties under this Deed;

  

	 	26.1.4	the making good of any such breach, non-observance or non-performance; 

  

	 	26.1.5	the enforcement of this Deed; or 

  

	 	26.1.6	any action, claim or proceeding relating to any of the above. 

  

	 	26.2	Obligation to pay 

 The Borrower shall, in
accordance with Clause 26.5 (Time for payment), pay to the Lender for the benefit of the Lender: 
  

	 	26.2.1	the items of expenditure set out in Clause 26.3 (Identification of expenses); and 

  

	 	26.2.2	the amount referred to in Clause 26.1 (General indemnity). 

  

 22 

	 	26.3	Identification of expenses 

 The items of
expenditure referred to in Clause 26.2.1 (Obligation to pay) are all expenses (including, without limitation, reasonable legal and out-of-pocket expenses on a full indemnity basis) reasonably and properly incurred by the Lender in connection
with: 
  

	 	26.3.1	the preparation, negotiation and execution of this Deed; 

  

	 	26.3.2	the preparation and negotiation of documentation relating to any amendment or extension of this Deed on terms agreeable to all parties thereto; 

  

	 	26.3.3	the granting, preparation and documenting of any waiver, approval, consent, confirmation or release under, or in respect of, this Deed; 

  

	 	26.3.4	any investigation or due diligence into the financial or other condition of the Borrower or SAVVIS, Inc. or into ascertaining whether or not the Borrower or SAVVIS, Inc. has
complied or is complying with this Deed; 

  

	 	26.3.5	the contemplation of the enforcement of any rights or the exercise of any powers under this Deed or in investigating any possible breach by either the Borrower or SAVVIS, Inc. of
this Deed; 

  

	 	26.3.6	any proceedings (legal or otherwise) involving the Lender in connection with this Deed or the Security Assets, whether such proceedings are brought by either the Borrower or SAVVIS,
Inc. or a third party; and 

  

	 	26.3.7	the matters referred to in Clause 21 (Subsequent Security Interests and New Accounts). 

  

	 	26.4	Stamp duties and other payments 

 In addition, the
Borrower shall, in accordance with the Clause 26.5 (Time for payment), pay an amount equal to any stamp duties, search fees, registration fees and duties payable in connection with this Deed and any penalties with respect to, or resulting
from, delay or omission to pay any such duties or fees. 
  

	 	26.5	Time for payment 

 The Borrower shall, on first
demand, pay or reimburse the Lender for the items of expenditure referred to in Clause 26.3 (Identification of expenses) and any amount referred to in Clause 26.4 (Stamp duties and other payments). 
  

 23 

	 	27	EFFECTIVENESS OF SECURITY 

  

	 	27.1	Continuing Security 

 This Security is a continuing
security and will not be considered satisfied by any intermediate payment or settlement of account or otherwise, but will remain in force until the end of the Security Period. 
  

	 	27.2	Rights additional 

 The rights of the Lender under
this Deed are in addition to any guarantee, other rights or Security Interest, present or future, held by the Lender from the Borrower or SAVVIS, Inc. or any other person in respect of the payment or discharge of the Secured Liabilities and will not
merge with, or prejudice or be prejudiced by, any such guarantee, rights or Security Interest or by any dealing with, exchanging, releasing, modifying or abstaining from perfecting or enforcing any of them, and this Deed may be enforced against the
Borrower or SAVVIS, Inc. (or either of them) without first having recourse to any guarantee, other rights or Security Interest in favour of the Lender. 
  

	 	27.3	Other dealing 

 This Security and its validity
shall not in any way be prejudiced or affected by the Lender dealing with, exchanging, releasing, modifying or abstaining from perfecting or enforcing any Security Interest, guarantee or other rights or remedies referred to in Clause 27.2 (Rights
additional) or by giving time for payment or indulgence or compounding with any other person liable. 
  

	 	27.4	Conditional release of security 

 Without prejudice
to Clause 1.8 (Irrevocable payment), if any Security Interest, disposition or payment made or given to the Lender is avoided, reduced, set aside, rendered unenforceable or required to be paid away by virtue of any provision, requirement or
enactment, whether relating to bankruptcy, insolvency or liquidation or otherwise at any time in force, or by virtue of any obligation to give effect to any preference or priority, the Lender shall be entitled to recover the value or amount of that
Security Interest, disposition or payment from the Borrower on demand. 
  

	 	27.5	Retention of Security 

 The Lender may retain this
Security and this Deed throughout the Security Period. 
  

	 	27.6	Change in constitution of the Lender 

 This Deed
and this Security shall be enforceable notwithstanding any change in the constitution of the Lender or its absorption of or amalgamation with or the acquisition of its respective undertakings by any third party. 
  

	 	27.7	Preservation of Security 

 If for any reason any
Security Interest intended to be created by this Deed ceases to be continuing security, such Security Interest shall remain effective as security in respect of the Secured Liabilities at the date of such cessation, regardless of any subsequent
increase or reduction in the amounts of any sums constituting Secured Liabilities. 
  

 24 

	 	27.8	Obligations of the Borrower and SAVVIS, Inc. 

  

	 	27.8.1	The obligations of each of the Borrower and SAVVIS, Inc. under this Deed are primary obligations. 

  

	 	27.8.2	The obligations of the Borrower and SAVVIS, Inc. under this Deed, the Security Interests intended to be created by this Deed, and the rights, powers and remedies of the Lender under
this Deed shall not be discharged, impaired or otherwise affected by: 

  

	 	27.8.2.1	any legal limitation, disability, incapacity or other circumstances relating to any other person; 

  

	 	27.8.2.2	the Winding-up, dissolution, administration or reorganisation of any other person or any change in its status, function, control or ownership; 

  

	 	27.8.2.3	any of the Secured Liabilities or any security therefor being or becoming illegal, invalid, unenforceable or ineffective in any respect; 

  

	 	27.8.2.4	time or other indulgence being granted or agreed to be granted to any other person in respect of any of the Secured Liabilities; 

  

	 	27.8.2.5	any amendment to, or any variation, waiver or release of, any of the Secured Liabilities however fundamental the same may be; 

  

	 	27.8.2.6	any failure to take, or fully to take, any security contemplated by any Finance Document or otherwise agreed to be taken in respect of the Secured Liabilities;

  

	 	27.8.2.7	any failure to realise, or fully to realise the value of, or any release, discharge, exchange or substitution of, any security taken in respect of the Secured Liabilities; or

  

	 	27.8.2.8	any other act, event or omission (other than an express discharge by the Lender in writing) which, but for this Clause 27.8.2, might operate to discharge, impair or otherwise affect
the security interest(s) created by this Deed or any of the obligations of the Borrower or SAVVIS, Inc. under this Deed or any of the rights, powers or remedies conferred upon the Lender by any Finance Document or by law. 

 

 25 

	 	27.9	Lender’s rights 

 The Lender shall not be
obliged before the exercise of the rights, powers or remedies conferred upon the Lender in respect of the Borrower or SAVVIS, Inc. or the Security Assets by any Finance Document or by law: 
  

	 	27.9.1	to make any demand of any other person; 

  

	 	27.9.2	to take any action or obtain judgment in any court against any other person; 

  

	 	27.9.3	to make or file any claim or proof in a Winding-up or dissolution of any other person; 

  

	 	27.9.4	to enforce or seek to enforce any other security taken in respect of the Secured Liabilities; and/or 

  

	 	27.9.5	to exercise any right of set-off, counterclaim or similar rights against any other person, or to have the benefit of any payment or other distribution from any other person.

  

	 	27.10	Perpetuity period 

 The perpetuity period for the
trusts contained in this Deed is 80 years from the date of this Deed. 
  

	 	28	REASSIGNMENT AND RELEASE OF SECURITY 

 On the
expiry of the Security Period, the Lender shall, at the request and cost of the Borrower and without any warranty or representation in connection with the reassignment, execute such reassignments and do all such other deeds, acts and things as may
be necessary to reassign those Security Assets (then in existence) which were assigned to the Lender and to release the remaining Security Assets from this Security. 
  

	 	29	MISCELLANEOUS 

  

	 	29.1	Certificate of Lender 

 The certificate of the
Lender as to: 
  

	 	29.1.1	any matter in relation to this Deed which is to be designated, calculated, decided, determined or certified by the Lender under, or in respect of, this Deed;

  

	 	29.1.2	the amount at any time of the Secured Liabilities or any other amount payable under this Deed; or 

  

	 	29.1.3	any rate of exchange or currencies, 

  

 26 

 shall be conclusive and binding on the Borrower and SAVVIS, Inc. unless there is an obvious error.

  

	 	29.2	Severability 

 If a provision of this Deed is or
becomes illegal, invalid or unenforceable in any jurisdiction, that shall not affect: 
  

	 	29.2.1	the validity or enforceability in that jurisdiction of any other provision of this Deed; or 

  

	 	29.2.2	the validity or enforceability in any other jurisdiction of that or any other provision of this Deed. 

  

	 	29.3	Waivers, remedies cumulative 

 The rights of the
Lender under this Deed: 
  

	 	29.3.1	may be exercised as often as the Lender considers necessary or desirable; 

  

	 	29.3.2	are cumulative and not exclusive of its respective rights under any applicable law; and 

  

	 	29.3.3	may be waived only in writing and specifically. 

  

	 	29.4	Delay 

 Delay in exercising or the non-exercise of
any right of the Lender under this Deed is not a waiver of that right. 
  

	 	30	ASSIGNMENTS, TRANSFER, ETC 

  

	 	30.1	Borrower 

 Neither the Borrower nor SAVVIS, Inc.
may assign, transfer or otherwise dispose of any of its rights or obligations under this Deed. 
  

	 	30.2	Lender 

  

	 	30.2.1	The benefit of this Deed may be assigned in whole or in part by the Lender without regard to any set-off, counterclaim or equities between the Borrower or SAVVIS, Inc. and the
Lender or any intermediate holder and each of the Borrower and SAVVIS, Inc. undertakes, promptly after being required to do so by the Lender, to enter into such documents as may be necessary or desirable to effect said transfer.

  

 27 

	 	30.2.2	Any assignment by the Lender must comply with the terms and conditions of Clause 31 of the Facility Agreement. 

  

	 	30.3	Disclosure of information 

 The Lender shall be
entitled to disclose any information concerning the Borrower or SAVVIS, Inc. and the Finance Documents as the Lender shall consider appropriate to a person to whom the Lender has assigned or purported to assign the benefit of this Deed or to any
person who may otherwise enter into or proposes to enter into contractual relations with the Lender in relation to this Deed if the person to whom the information is to be given has entered into a Confidentiality Undertaking (substantially in the
form most recently recommended (or suggested) by the LMA). 
  

	 	31	NOTICES 

  

	 	31.1	Communications in accordance with the Facility Agreement 

 Each communication to be made under this Deed shall be made in accordance with Clause 35 (Notices) of the Facility Agreement. 
  

	 	32	COUNTERPARTS 

 This Deed may be executed in any
number of counterparts and this has the same effect as if the signatures on the counterparts were on a single copy of this Deed. 
  

	 	33	NON-CONTRAVENTION 

 It is hereby certified that the
Security created hereby does not contravene any of the provisions of the Memorandum or Articles of Association of the Borrower or any constitutional documents relating to SAVVIS, Inc. 
  

	 	34	AMENDMENT 

 Any term of this Deed may be amended or
waived only with the consent of the Lender, the Borrower and SAVVIS, Inc. and in accordance with the terms of the Intercreditor Agreement and any such amendment or waiver will be binding on all parties. 
  

	 	35	GOVERNING LAW 

 This Deed is governed by English
law. 
  

	 	36	ENFORCEMENT 

  

	 	36.1	Jurisdiction and Agent for Services of Process 

 Clause 43 (Jurisdiction) and 44 (Agent for Service of Process) of the Facility Agreement shall apply, mutatis mutandis, to this Deed. 
  

 28 

 This Deed has been executed as a Deed and delivered as a deed on the date stated at the beginning of
this Deed. 
  

 29 

							
	THE BORROWER	 	)	 		  	
				
	SIGNED as a DEED by	 	)	 		  	
				
	SAVVIS UK LIMITED	 	)	 	 /s/ Jeffrey H. Von Deylen
	  	
				
	acting by Jeffrey H Von Deylen and	 	)	 		  	
		
	Edward Mueller	 	Director
				
		 		 	 /s/ Edward Mueller
	  	
		
	Address: Eskdale Road, Winnersh	 	Director/Secretary
	Triangle, Wokingham,	 		 		  	
				
	Berkshire RG41 5TS	 		 		  	
				
	Facsimile no: 44 (0)118 322 6092	 		 		  	
				
	Attention: Secretary	 		 		  	
				
	THE GUARANTOR	 	)	 		  	
				
	Executed as a Deed	 	)	 		  	
				
	by	 	)	 	 /s/ Jeffrey H. Von Deylen
	  	
				
	SAVVIS, Inc., a Delaware Corporation	 	)	 		  	
		
	acting by	 	Authorised Signatory
				
	 being persons who in accordance with
 the laws of
that territory are acting
 under the authority of and for and on
 behalf of SAVVIS, Inc.
	 		 	 /s/ Meredith M. Graham
	  	
		
		 	Authorised Signatory
				
	 Address: One SAVVIS Parkway, Town
 & Country,
Missouri 63017 USA
	 		 		  	
				
	Facsimile no: 314 628 7450	 		 		  	
				
	Attention: Chief Financial	 		 		  	

  

 30 

							
	THE LENDER	 	)	 		  	
				
	SIGNED for and on behalf of	 	)	 		  	
	LOMBARD NORTH CENTRAL PLC	 	)	 	 /s/ P. A. Stranaghan
	  	
		
		 	Attorney
				
	 Address: 3 Princess Way, Redhill,
 Surrey RH1
1NP
	 		 		  	
		 		 	 /s/ Ian Tyrer
	  	
	Facsimile no: 44 (0)1737 774466	 		 		  	
				
	Attention: Corporate Relationship Manager	 		 		  	

  

 31

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00144-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00144-of-00352.parquet"}]]