Document:

Exhibit
10.15

 

AGREEMENT
BETWEEN

 

Kokku
Games Ltda. (“Kokku”), organized under the laws of Brazil and located at 2589, Eng. Domingos Ferreira Av. - 9th
Floor - Boa Viagem. City of Recife. State of Pernambuco, Brazil. ZIP CODE: 51020-030. Company Registration: 14.886.508/0001-43 (“the
“Developer”), and VNUE, Inc., a Nevada corporation, (“Client”), each a “Party”
and collectively referred to as the “Parties.”

 

In
consideration of the mutual promises and obligations set forth below, the adequacy and sufficiency of which is hereby acknowledged, Kokku
and Client agree as follows (the “Agreement”):

 

CLAUSE
ONE – SERVICES

 

 

1.

 

1.1.
Kokku will provide the services set forth in this Agreement and other complements which reference this Agreement that are identified
as Statements of Work (each a “SOW”) (the “Services”). All Services shall be performed in a timely business-like
manner in accordance with industry standards and in accordance with this Agreement and as set forth in SOW(s) attached hereto and incorporated
herein by this reference.

 

1.2.
Kokku shall serve as a contractor of the Client and shall design, develop, and implement the Deliverables according to
the functional specifications and related information provided by the Client and as more fully set forth in this Agreement and
other briefing documentation provided by the Client, which will form part of a SOW. “Deliverable(s)” means any element
of the Services, whether tangible or intangible, performed by Kokku as reflected in a SOW.

 

CLAUSE
TWO - PAYMENTS AND NATURE OF RELATIONSHIP

 

 

2.1.
In consideration of the Services Client will pay Kokku the amount as set forth in the SOW, attached hereto and
incorporated herein by this reference.

 

2.2.
Each Party is solely responsible for its own income and employment related taxes.

 

     

     

    

 

2.3.
The relationship of the Parties under this Agreement is one of independent contractors, and no joint venture, partnership, agency,
employer-employee, or similar relationship is created in or by this Agreement. Neither Party may assume or create obligations on the
other Party’s behalf and neither Party may take any action that creates the appearance of such authority.

 

2.4.
Kokku has the sole right to control and direct the means, details, manner, and method by which the Services will be performed,
and the right to perform the Services at any time, place, or location. Kokku’s employees shall perform the Services, and
Client is not required to hire, supervise, or pay any assistants to help Kokku perform those Services. Kokku has
no claim against the Client under this Agreement or otherwise for vacation pay, sick leave, retirement benefits, social security,
worker’s compensation, health or disability benefits, unemployment insurance benefits, or employee benefits of any kind. The fees
set forth in this Agreement are Kokku’s only compensation under this Agreement. Any ordinary and necessary expenses incurred
by Kokku or its staff in performing under this Agreement are Kokku’s sole responsibility.

 

2.5.
The Parties agree that the Services stated in this Agreement may be delivered only by Kokku itself and no other party unless agreed
by Client. Kokku shall be solely liable for its performance in accordance with the terms of this Agreement. In any event,
where Kokku requires subcontractors to perform certain tasks for the Client project, it must be agreed between the parties
and Kokku shall make the Client aware of such performance and Kokku must also make subcontractor be aware of the
confidentiality provisions contained in Clause Seven, hereof and obtain a written acknowledgment from such subcontractor(s) that they
will comply with the same.

 

CLAUSE
THREE – OWNERSHIP

 

 

3.1.
Client retains all right, title and interest in and to Client Materials. “Client Materials” means any data,
software, documents, intellectual property rights, artwork, logos and any other material or information owned or developed by Client
that is delivered or made available to Kokku under this Agreement. Kokku acknowledges that nothing in this Agreement shall be
construed as granting Kokku any license, right, title or ownership interest in or to Client Materials except to the extent
specifically set out in this Agreement.

 

    2

     

    

 

3.2.
In addition, Client will receive transfer and own all right, title and interest in the Deliverables provided to the Client by Kokku once
payments for the work are made to Kokku in full. Upon full payment stipulated for the work, all work, Services, materials and
Deliverables are the property of the Client and all title and interest therein shall vest the Client and shall be
deemed to be a “work for hire” (and made in the course of Services rendered hereunder) as that term is used in
conjunction with copyright laws (and to the extent that title may not, by operation of law, vest in Client or be considered a
“work for hire”, Kokku hereby irrevocably assigns to Client all right, title and interest in and to such
items to Client), limited only to the extent such work does not include Kokku Materials. “Kokku Materials”
means any data, software, documents, intellectual property rights, artwork, logos and any other material or information owned or
developed by Kokku that is not a part of the Services or Deliverables. To the extent that any work, Services, materials or
Deliverable includes, in part or in whole, any Kokku Materials, Kokku grants Client a perpetual, royalty free,
worldwide license to use those materials in a manner consistent with the terms and purposes set out in this Agreement provided that
all fees under this Agreement are paid in full.

 

3.3.
Kokku retains all right title and interest in and to Kokku Materials including, but not limited, to the related documentation
and the Client acknowledges that nothing in this Agreement shall be construed as granting Client any license, right, title
or ownership interest in or to Kokku Materials, except as specifically set out in this Agreement.

 

CLAUSE
FOUR – REPRESENTATIONS AND WARRANTIES

 

 

4.1.
Kokku makes the following representations and warranties to the Client:

 

4.1.1.
In providing Services to the Client, Kokku will not knowingly infringe upon or misappropriate any third-party trade secrets,
copyrights, trademarks, or rights of publicity or privacy;

 

4.1.2.
Kokku has all necessary rights to grant and assign to the Client the various rights set forth in this Agreement and Kokku
has not previously granted and will not grant any rights to any third party which are inconsistent with the rights granted to the
Client herein;

 

4.1.3.
Kokku will comply with all applicable laws, regulations, ordinances and statutes, including, but not limited to, the import/export
laws and regulations of any applicable governmental and regulatory agencies and all applicable international treaties and laws;

 

4.1.4.
Kokku has full corporate power to enter into this Agreement, to carry out its obligations hereunder and to grant the rights herein
granted to Client;

 

    3

     

    

 

4.1.5.
Any Deliverables provided to the Client by Kokku under this Agreement will not contain any known viruses, and will function
substantially in accordance with its documentation in all material respects and does not and will not contain any undisclosed software,
copyrighted works or other material owned by any third party, including, without limitation, any “open source”
software, “shareware,” “freeware” or similar software.

 

4.2.
The Client makes the following representations and warranties to Kokku:

 

4.2.1.
The Client, both in whole and in part, do not and will not infringe upon or misappropriate any third-party trade secrets, copyrights,
trademarks, or rights of publicity;

 

4.2.2.
The Client will comply with all applicable laws, regulations, ordinances and statutes, including, but not limited to, the import/export
laws and regulations of any applicable governmental and regulatory agencies and all applicable international treaties and laws;

 

4.2.3.
Client has full power to enter into this Agreement and to carry out its obligations hereunder and to grant the rights herein granted
to Kokku.

 

4.3.
Kokku shall provide all the project Deliverables in agreed schedule. The Deliverables scope, form, schedule and delivery method
are to be decided and agreed between the Parties as work scope described in briefing documents provided by the Client such as
pdf files or notes, or more and reflected in a SOW.

 

CLAUSE
FIVE - INDEMNIFICATION

 

 

5.1
Kokku agrees to indemnify, hold harmless and defend Client from all claims, defense costs (including reasonable attorneys’
fees), settlements, judgments and other expenses arising out of or because the following:

 

(i)
alleged facts or circumstances that, if true, would constitute a breach of any express warranties with respect to the Services provided
under this Agreement;

 

(ii)
alleged infringement or violation of any trademark, copyright, trade secret, or other proprietary right with respect to the Services;

 

(iii)
unfair trade practice, trade libel or misrepresentation based on any promotional material, documentation or other materials provided
by Kokku with respect to the Services.

 

    4

     

    

 

Notwithstanding
the above, Kokku shall have no liability to the Client for any claim to the extent that such claim is based upon any element
of the Client or to the extent that it is a claim for which Client has agreed to indemnify Kokku.

 

5.2
The Client agrees to indemnify, hold harmless and defend Kokku from all claims, defense costs (including reasonable attorneys’
fees), judgments, settlements and other expenses arising out of the following:

 

(i)
claims of unfair trade practice, trade libel or misrepresentation arising out of or because the Client (other than those claims
for which Kokku has agreed to indemnify the Client);

 

(ii)
alleged infringement or violation of any trademark, copyright, trade secret, patent or other proprietary right with respect to Client;

 

(iii) alleged
facts or circumstances that, if true, would constitute a breach of Client’s warranties set forth.

 

5.3
If any action shall be brought against one of the Parties hereto in respect to which indemnity may be sought against the other Party
(the “Indemnifying Party”) pursuant to this Clause 5, the Indemnifying Party’s obligation to provide
such indemnification will be conditioned on prompt notice of such claim (including the nature of the claim and the amount of damages
and nature of other relief sought) being provided to the Indemnifying Party by the Party against which such action is brought (the “Indemnified
Party”). The Indemnified Party shall cooperate with the Indemnifying Party in all reasonable respects in connection with
the defense of any such action at the expense of the Indemnifying Party. The Indemnifying Party may, upon written notice to the Indemnified
Party, undertake to conduct all proceedings or negotiations relating to the action, assume the defense thereof, including settlement
negotiations relating to the action, and be responsible for the costs of such defense, negotiations and proceedings. The Indemnifying
Party will have sole control of the defense and settlement of any claims for which it provides indemnification hereunder, provided that
the Indemnifying Party will not enter into any settlement of such claim without the prior approval of the Indemnified Party, which approval
will not be unreasonably withheld. The Indemnified Party shall have the right to retain separate counsel and participate in the defense
of the action or claim at its own expense.

 

    5

     

    

 

CLAUSE
SIX – LIMITATION OF LIABILITY

 

 

6.1
Neither Party will be liable to the other Party for indirect, special, incidental, consequential or punitive damages or the loss of anticipated
profits arising out of or relating to any breach of this agreement by such Party, even if such Party is notified of the possibility of
such damages and regardless of whether any remedy set forth herein fails of its essential purpose.

 

CLAUSE
SEVEN – CONFIDENTIALITY

 

 

7.1
Kokku and the Client acknowledge that, during performing their respective obligations hereunder, each may obtain information
relating to the other and the other’s products that are of a confidential and proprietary nature to such other Party (“Confidential
Information”). Such Confidential Information includes but is not limited to any information, technical data or know-how, including,
without limitation, that which relates to computer software programs or documentation, specifications, source code, object code, research,
inventions, processes, designs, drawings, engineering, products, services, customers, markets or finances of the disclosing Party which
(a) has been marked as confidential or proprietary, (b) is identified as confidential at the time of disclosure either orally or in writing,
or (c) which, due to its character and nature, a reasonable person under like circumstances would treat as confidential.

 

7.2
Each Party agrees that it will (a) use the other Party’s Confidential
Information only in connection with fulfilling its obligations and exercising its rights and licenses under this Agreement; (b) hold
the other Party’s Confidential Information in strict confidence and exercise due care with respect to its handling and protection,
consistent with its own policies concerning protection of its confidential information of a similar nature, (c) not directly or indirectly
reverse engineer, disassemble, or decompile the other Party’s Confidential Information consisting of binary code; (d) not disclose,
divulge, or publish the other Party’s Confidential Information except to such of its responsible employees, and consultants (collectively,
“Personnel”) who have a bona fide need to know to the extent necessary to fulfill such Party’s obligations under this
Agreement; and (e) instruct all such Personnel not to disclose the other Party’s Confidential Information to third parties. Each
Party shall require all Personnel who shall encounter the Confidential Information of the other Party to execute a confidentiality agreement
at least as protective of the rights in such Confidential Information as the terms and conditions of this Agreement, prior to such Personnel
being given access to any Confidential Information. Each Party shall be responsible for breaches of this Agreement by its Personnel.

 

    6

     

    

 

7.3
The obligations set forth above will not apply to either Party’s Confidential Information which (i) is or becomes public knowledge
without the fault or action of the recipient Party, or which (ii) the recipient Party can document was independently developed by it
without use of Confidential Information of the other Party; or which (iii) the recipient Party can document was already known to it,
on a non-confidential basis, prior to the receipt of the other Party’s Confidential Information from a source (a) that was not
bound by a confidentiality agreement with the recipient Party or (b) is not otherwise prohibited from transmitting the information to
the disclosing Party by a contractual, legal, fiduciary or other obligation.

 

7.4
If either Party is required to disclose any Confidential Information pursuant to an order under law, it shall not be a breach of this
Section to disclose such information provided that it shall use its reasonable efforts to give the Party owning the Confidential Information
sufficient notice of such required disclosure to allow the Party owning the Confidential Information reasonable opportunity to object
to and take necessary legal action to prevent such disclosure. Money damages may not be a sufficient remedy of this section and, in addition
to any other remedies, a Party may seek (and may be entitled to) as a result of such breach, injunctive or other equitable relief as
a remedy.

 

CLAUSE
EIGHT – ACCEPTANCE

 

 

8.

 

8.1
Upon completing the full scope of works or separate sprints, Kokku presents to the Client a written request to accept or
reject the software components and the Deliverables (each a “Deed of Acceptance”). Within 5 (five) working days of receipt
of the software Deliverables, subject to this Agreement, the Client shall sign and return to Kokku the Deed of Acceptance
or send a motivated refusal to accept.

 

8.2
In case the Client sends a motivated refusal, the parties shall draw up an act listing all corrections required, deadlines for
completion, signed by the representatives of the Client and Kokku.

 

8.3
In case Kokku has not received either a signed Deed of Acceptance or a motivated refusal within 14 (fourteen) working days on
the dispatch of the software Deliverables, the Deliverables are deemed to be accepted by the Client in full.

 

    7

     

    

 

CLAUSE
NINE – TERM AND TERMINATION

 

 

9.1.
This Agreement shall remain in force until the obligations of each Party under this Agreement are fulfilled, and each Party has notified
the other Party thereof in writing.

 

9.2
In the event of a material breach by either Party of a material provision hereof, which breach is not cured within 10 (ten) days after
written notice thereof by the other Party, then the non-breaching Party may, after written notice of failure to cure to the breaching
Party, terminate this Agreement. In addition to or instead of its rights to terminate this Agreement upon a material breach by the other
Party, each Party will have the right to pursue any remedies it may have at law or in equity.

 

9.3
The occurrence of any of the following events shall be deemed a material breach of this Agreement:

 

9.3.1.
Kokku fails to meet any Milestone (as defined in a SOW);

 

9.3.2.
Either Party breaches any of the Representations and Warranties set forth in Clause 4 of this Agreement;

 

9.3.3.
Client breaches its payment obligations under Clause 2;

 

9.3.4.
Either Party breaches the Confidentiality provisions set forth in Clause 7.

 

CLAUSE
TEN – APPLICABLE LAW AND DISPUTE RESOLUTION

 

 

10.

 

10.1.
The Parties shall primarily attempt to resolve any dispute, controversy or claim under or in relation to this Agreement (each a “Dispute”)
through friendly negotiations. In case the Parties fail to settle the Dispute within 30 (thirty) days from the commencement of such negotiations,
either Party shall be entitled to initiate proceedings as set forth below for final resolution of the Dispute.

 

    8

     

    

 

10.2
Subject to Clause 10.1, the Parties agree to settle the Dispute by binding, confidential arbitration ruled by a sole arbitrator to be
administered by the Judicial Arbitration and Mediation Services’ {“JAMS”) Comprehensive Commercial Arbitration Rules
in effect at the time the request for arbitration is made, when the Arbitration Claimant is Client. If the Arbitration Claimant is Kokku,
the Parties agree to settle the Dispute by binding, confidential arbitration to be administered by CAMARB – Business Mediation
and Arbitration Chamber – Brazil, in compliance with the provisions of its Arbitration Rules in effect at the time the request
for arbitration is made, ruled by a sole arbitrator,

 

10.2.1
The Parties agree that any hearing, proceeding, or conference conducted as part of the arbitration may be held virtually. Each Party
shall pay its own costs and expenses for the arbitration, with the cost of the Arbitrator to be divided equally between the Parties.
Any award or decision in arbitration shall be final and binding upon the Parties and shall be enforceable by judgment of any court of
competent jurisdiction.

 

10.3
If the Dispute involves an alleged breach of this Agreement by Client, then Kokku may commence an arbitration in Recife, Pernambuco,
Brazil, the resolution of the Dispute shall be governed by the laws of Brazil and the language will be Portuguese. If the Dispute involves
an alleged breach of this Agreement by Kokku, then Client may commence arbitration in New York, New York and the resolution of the Dispute
shall be governed by the laws of the State of New York and the language will be English.

 

CLAUSE
ELEVEN – GENERAL TERMS

 

 

11.1
This Agreement may not be assigned in whole or in part by either Party without consent of the other, which will not be unreasonably withheld.
Notwithstanding the foregoing either Party may assign such Party’s rights and duties under this Agreement to an Affiliate or to
any third party which succeeds by operation of law to, purchases or otherwise acquires substantially all the assets of such Party or
Affiliate, provided such party assumes all rights and obligations of the assigning Party under this Agreement.

 

11.2
This Agreement has been fully negotiated by the Parties and will be interpreted according to the plain meaning of its terms without any
presumption that it should be construed either for or against either Party.

 

11.3
All notices delivered in connection this Agreement must be given in writing. Notices with a claimed breach or termination of the Agreement
will be deemed given as of

 

		(i)	the
                                            day they are delivered on paper by a nationally recognized express delivery service (such
                                            as Federal Express or DHL), addressed as set forth below; or

 

    9

     

    

 

		(ii)	the
                                            day they are sent by fax to the fax number set forth below, but only if the receiving fax
                                            device immediately generates a message, printed by the sending fax device, that confirms
                                            transmission and the correct recipient fax number. Other than for a notice of breach or termination,
                                            notice sent by email is sufficient.

 

11.4
No waiver of any provision of this Agreement will be effective unless it is in a signed writing, and no such waiver will constitute a
waiver of any other provision(s) or of the same provision on another occasion.

 

11.5
Neither Party will be deemed in default of this Agreement to the extent that performance of its obligations or attempts to cure any breach
are delayed or prevented by reason of any act of God, fire, natural disaster, accident, act of government, shortages of material or supplies
or any other cause reasonably beyond the control of such Party (“Force Majeure”), provided that such Party gives the other
Party written notice thereof promptly and, in any event, within 15 (fifteen) days of discovery thereof, and uses its diligent, good faith
efforts to cure the breach. In the event of such a Force Majeure, the time for performance or cure will be extended for a period equal
to the duration of the Force Majeure but not more than 60 (sixty) days.

 

11.6
If an arbitrator or court of competent jurisdiction holds any term, covenant or restriction of this Agreement to be illegal, invalid
or unenforceable, in whole or in part, the remaining terms, covenants and provisions will remain in full force and effect and will in
no way be affected, impaired or invalidated. If any provision in this Agreement is determined to be unenforceable in equity because of
its scope, duration, geographical area or other factor, then the court making that determination will have the power to reduce or limit
such scope, duration, area or other factor, and such provision will be then enforceable in equity in its reduced or limited form.

 

11.7
This Agreement is not effective until signed by both Parties. This Agreement, including any “SOW” attached hereto which are
incorporated by this reference, constitutes the entire agreement between the Parties with respect to the subject matter hereof and merges
all prior and contemporaneous communications and proposals, whether electronic, oral or written, between the parties.

 

11.8
This Agreement may not be modified except by a written Amendment dated after the date of this Agreement and signed by appropriately authorized
representative of both Parties.

 

11.9
This Agreement may be signed in counterparts which will be taken together to comprise a single agreement. Digital, scanned or facsimile
transmitted signatures will be treated as valid originals for all purposes.

 

    10

     

    

 

CLAUSE
TWELVE – NON-SOLICITATION

 

 

12.1
Parties agree that within the term of this Agreement and for a period of 12 months following its termination or the commercial release
of the last Product, a Party will not directly or indirectly solicit or otherwise take away the other Party’s employees, full-time
consultants or full-time individual contractors of whom a Party became aware as a result of the engagement under this Agreement. For
the avoidance of doubt, a general advertisement by a Party for employment that is not targeted at any specific employee/contractor shall
not constitute a breach of the obligations of such Party. In such a case, if an employee/contractor applies to a Party, the other Party
shall be informed at the earliest convenience: as soon as reasonably practicable and legally permissible.

 

This
Agreement has been executed in 02 (two) identical copies of which the parties have retained one each.

 

Agreed
to and accepted by:

 

	KOKKU
                                            GAMES LTDA 

	 	CLIENT
                                            

	 	 	 	 	 
	Place
    and date: 
	Recife,
                                            Oct 12th, 2022
	 	Place
    and date: 
	New
                                            York, Oct 12th, 2022

	Signature:     
	/s/
    Thiago de Freitas	 	Signature:     
	/s/
    Zach     Bair
	Printed
    name: 
	Thiago
    de Freitas (CEO)
	 	Printed
    name: 
	Zach
    Bair (CEO)

	 	(authorized representative of Developer)	 	 	(authorized representative of the Client)

 

    11Exhibit
10.2

 

Pursuant
to Item 601(b)(10)(iv) of Regulation S-K, certain identified information marked with [*****] has been excluded from the exhibit because
it is both (i) not material and (ii) would be competitively harmful if publicly disclosed.

 

SERVICE
AGREEMENT

 

This
Service Agreement (“Agreement”) is made of and entered into on 08th September 2021 between CytoMed
Therapeutics (Malaysia) Sdn. Bhd. (“Company”) and Choo Chee Kong (“Service Provider”).

 

BETWEEN

 

(1)
       CHOO CHEE KONG (Singapore National ID : [*****]) of [*****] (the “Service Provider”);

 

AND

 

(2)        CYTOMED THERAPEUTICS (MALAYSIA) SDN. BHD. (Registration Number: 201301044786 (1074609-M)),
a company incorporated in Malaysia and having its registered office at Room 503, 5th Floor Merlin Tower, Jalan Meldrum, 80000
Johor Bahru, Johor (the “Company”).

 

The
Company and the Service Provider shall hereinafter be referred to singularly as “Party” and collectively as “Parties”.

 

WHEREBY
IT IS AGREED as follows:

 

	1.	Scope
                                            of Work

 

To
provide Business Development and Marketing Services (“Workscope”) to the Company. Subject to mutual agreement, this
engagement could be extended to CytoMed Therapeutics Pte Ltd (“CytoMed”, and together with its subsidiaries, the “CytoMed
Group”).

 

	2.	Date
                                            of Commencement and Term of Engagement

 

The
initial term of this engagement shall commence on 08th September 2021 and it shall continue in effect for a period of one
(1) year ending on 07th September 2022 (“Initial Term”).

 

Thereafter,
this Agreement shall be renewed automatically for additional one (1) year term unless terminated by a Party in accordance to Clause 8
hereinbelow.

 

	3.	Duties
                                            and Responsibilities

 

		3.1	Under
                                            the Workscope, the duties and responsibilities of the Service Provider shall be as follows:

 

		(a)	devote
                                            effort to developing, promoting and managing the Company’s business interests and shall
                                            act at all times in a prudent manner to preserve the reputation and integrity of the Company.

 

    	 

    	 

    

 

		(b)	at
                                            all times carry out the duties of that position as assigned to the Service Provider from
                                            time to time and all incidental duties in a diligent, timely and competent manner.
	 	 	 
		(c)	not
                                            represent any other company in the same industry or engage in any other commercial activity
                                            or activities with such companies without the prior written consent of the Company; and
	 	 	 
		(d)	use
                                            the best efforts to be in constant communication with others in the Company’s industry
                                            to further the business interests of the Company and shall keep the Company fully and constantly
                                            advised of the market conditions and developments.

 

		3.2	The
                                            responsibilities of the Service Provider shall include:

 

		(a)	analyse
                                            market trend and competitor’s position;
	 	 	 
		(b)	develop
                                            and execute business and marketing strategies to expand existing and new market;
	 	 	 
		(c)	networking
                                            with customers and collaborators;
	 	 	 
		(d)	receive
                                            and review customers and collaborators’ enquiry; and
	 	 	 
		(e)	any
                                            ad-hoc tasks as instructed by the Company.

 

	4.	Place
                                            of Service 

 

Principal
place of service shall be in Singapore.

 

	5.	Tax
                                            Liability

 

All
taxers including personal income taxes liabilities in Singapore and Malaysia shall be on the account of the Service Provider.

 

	6.	Service
                                            Fee

 

As
full compensation for the services rendered pursuant to this Agreement, the Company shall pay the Service Provider the sum of RM 2,000.00/=
per month, to be paid at the last working day of the month to the following bank account:

 

    	 

    	 

    

 

	 	Beneficiary	[*****]
	 	 	 
	 	Beneficiary’s
    Bank	[*****]
	 	 	 
	 	Beneficiary’s
    Bank Address	[*****]
	 	 	 
	 	Beneficiary’s
    Bank Account No.	[*****]
	 	 	 
	 	Swift
    Code	[*****]

 

The
Service Provider shall not be entitled to any overtime claim. Visa, accommodations, airfares, travel insurance, petrol, entertainment
fee shall be at the Company’s costs.

 

	7.	Expenses

 

During
the term of this Agreement, the Service Provider shall submit the expenses according to the claim format as advised by the Company and
the Company shall reimburse the Service Provider for all reasonable and approved out-of-pocket expenses which are incurred in connection
with the performance of the Workscope specified hereinabove. Notwithstanding the foregoing, expenses for the time spent by the Service
Provider in traveling to and from the Company office shall not be reimbursable.

 

	8.	Termination

 

Any
Party may terminate this Agreement at any time by three (3) months’ advance written notice to the other Party, unless otherwise
agreed between the Parties. In addition, if the Service Provider is convicted of any crime or offense, fails or refuses to comply with
the written policies or reasonable directive of the Company, is guilty of serious misconduct in connection with performance hereunder,
or materially breaches provisions of this Agreement, the Company at any time may terminate the engagement of the Service Provider immediately
and without prior written notice to the Service Provider.

 

	9.	Independent
                                            Service Provider

 

This
Agreement shall not render the Service Provider an employee, partner, agent of, or party to a joint venture with the Company for any
purpose. The Service Provider is and will remain an independent service provider in his relationship to the Company. The Company shall
not be responsible for withholding taxes with respect to the Service Provider’s compensation/service fee hereunder. The Service
Provider shall have no claim against the Company hereunder or otherwise for vacation pay, sick leave, retirement benefits, social security,
worker’s compensation, health or disability benefits, unemployment insurance benefits, statutory contributions or employee benefits
of any kind.

 

	10.	Notices 

 

Any
notice required by this Agreement or given in connection with it, shall be in writing and shall be given to the appropriate party by
personal delivery or by certified mail, postage prepaid, return receipt requested;

 

    	 

    	 

    

 

	 	Company	Attention

                                                                               

    Designation

     

    Tel

     

    Email

     

    Postal
    Address
	:
                                            [*****]

     

    :
    Director

     

    :
    [*****]

     

    :
    [*****]

     

    :
    No.12, Jalan Permas 9/16

     

    Bandar
    Baru Permas Jaya, 81750 Masai, Johor,

    Malaysia.

	 	 	 	 
	 	Service
    Provider	Attention

     

    Tel

     

    Email

     

    Postal
    Address
	:
                                            Peter Choo

     

    :
    [*****]

     

    :
    [*****]

     

    :
    [*****]

 

11.       Confidentiality

 

The
Company is committed to taking whatever steps necessary or desirable to protect what it views as its proprietary or confidential information.
While appointed pursuant to these terms, Service Provider shall protect and guard such information, and shall keep with complete secrecy
all proprietary and confidential information entrusted to Service Provider. Except for the purpose of performing Service Provider’s
responsibilities under these terms, Service Provider shall not directly or indirectly use, disseminate, disclose, lecture upon or publish
articles concerning such information without the Company’s prior consent. For this purpose, proprietary or confidential information
includes any information developed, used in or relating to the business of the Company. The Service Provider may be asked from time to
time to sign the Company’s standard confidentiality agreement to confirm Service Provider’s confidential and other fiduciary
obligation to the Company. The Service Provider agrees that consent is given to the Company to collect, record, store, use and process
“Personal Data” as defined by the Personal Data Protection Act 2010 relating to the Service Provider for all purposes relating
to the Workscope.

 

The
provision of this Clause shall continue to apply after the termination of this Agreement without limit in point of time, but shall cease
to apply to information or knowledge which may legally come into the public domain other than by way of unauthorised disclosure by Service
Provider.

 

12.       Non-solicitation
and non-competition

 

The
Service Provider shall not at any time either during the continuance of the engagement hereunder or within one (1) year thereafter either
on Service Provider’s own account or for any other person or body corporate or unincorporated directly or indirectly entice away
from the Company, or its associated companies any person who now is or shall at any time during or at the date of the termination of
this Agreement be an employee of the Company or its associated companies or induce, persuade or suggest to such employee that he or she
shall leave the employment of the Company or its associated companies.

 

The
Service Provider covenants with the Company that Service Provider shall not within the area of Service Provider’s responsibility
or expertise for a period of one (1) year after termination of this Agreement without the prior written consent of the Company, either
on Service Provider’s own account or for any other person, directly or indirectly, solicit, interfere with or endeavour to entice
away from the Company, any person or company who is or has been a client, customer or executive of or in the habit of dealing with the
Company. The Company reserves the right to take any action, legal or otherwise, against Service Provider should the Service Provider
breach the above undertaking in letter and in spirit. Moreover, the Service Provider agrees to indemnify the Company for any loss howsoever
caused by the Service Provider breach of the above undertaking.

 

    	 

    	 

    

 

13.       Conflict
Of Interest 

 

13.1       Service
Provider shall not, without the consent of the Company, be directly or indirectly employed, engaged, concerned with or hold office or
position, (whether as an employee, agent, independent contractor or otherwise) in any organisation, enterprise, employer or business
or trade where a conflict of interest or potential conflict of interest may arise between his personal interest and the interest of the
Company for as long as Service Provider is engaged by the Company.

 

13.2       Service
Provider must not venture into any kind of activities that may be in conflict with the Company/holding or subsidiary or associated Company
interests. The Service Provider must obtain the prior written approval of the

 

Company
before assuming other opportunities for financial gain whilst within our appointment.

 

14.
       Intellectual Property

 

Any
process, procedure, program, discovery, idea, formulae, improvement, development, technology, design, invention (collectively “Inventions”),
whether or not patentable or copyrightable, conceived, developed, invented or made solely by the Service Provider, or jointly with others,
while in the service of the Company in connection with or in any way affecting or relating to the business of the Company, its related
corporations and/or associated companies (a “Group Company”) or capable of being used or adapted for use therein or
in connection therewith shall forthwith be disclosed to the Company and shall belong to and be the absolute property of the Company or
such other Group Company as the Company may nominate for the purpose.

 

The
Service Provider, if and whenever required so to do (whether during or after the termination of his engagement), shall at the expense
of the Company or its nominee apply or join in applying for letters patent or other similar protection in the Republic of Singapore or
any other part of the world for any such Inventions as aforesaid and execute all instruments and do all things necessary for vesting
the said letters patent or other similar protections when obtained and all right and title to and interest in the same in the Company
and/or its nominee absolutely and as sole beneficial owner or in such other person as the Company may require.

 

15.       
Other General Terms & Conditions

 

If,
in the opinion of the Company, the Service Provider shall at any time neglect or refuse to perform or comply with all lawful directions
given by the Company, in pursuance of this appointment or fail to observe any of the conditions or stipulations of this appointment or
if found guilty of insobriety or misconduct, breach of trust or dishonesty or incompetent or untrustworthy or any way misconduct at work,
the Company may immediately, and without assigning any reason, terminate this Agreement hereunder and in any such case, the Service Provider
will not be entitled to the payment of any sum by the Company either by way of monies or otherwise but this provision shall not in any
way prejudice the right of the Company to claim damages for breach of the Agreement by the Service Provider.

 

    	 

    	 

    

 

16.       
Modification of Agreement

 

No
provision of this Agreement may be waived, amended or modified unless in writing by the Parties hereto.

 

17.
       Governing Law and jurisdiction

 

This
Agreement shall be governed by the laws of Malaysia and each of the parties hereto submits to the non-exclusive jurisdiction of the courts
of Malaysia.

 

18.
      Severance

 

If
any provision or part-provision of this Agreement is or becomes invalid, illegal, or unenforceable, it shall be deemed modified to the
minimum extent necessary to make it valid, legal, and enforceable. If such modification is not possible, the relevant provision or part-provision
shall be deemed deleted. Any modification to or deletion of a provision or part-provision under this Clause shall not affect the validity
and enforceability of the rest of this Agreement.

 

19.       Waiver

 

A
waiver of any right or remedy under this Agreement or law is only effective if given in writing and shall not be deemed a waiver of any
subsequent breach or default. No failure or delay by a Party to exercise any right or remedy provided under this Agreement or by law
shall constitute a waiver of that or any other right or remedy, nor shall it prevent or restrict the further exercise of that or any
other right or remedy. No single or partial exercise of such right or remedy shall prevent or restrict the further exercise of that or
any other right or remedy.

 

20.       
Third party rights

 

A
person who is not a party to this Agreement has no right to enforce any term of this Agreement.

 

21.       
Entire agreement

 

This
Agreement constitutes the entire agreement between the Parties and supersede all prior communications, negotiations, representations,
and agreements between the Parties concerning the subject matter.

 

22.       
Counterparts

 

This
Agreement may be executed in 2 or more counterparts, each of which shall be deemed an original, but all of which together shall constitute
one and the same instrument.

 

    	 

    	 

    

 

IN
WITNESS WHEREOF, the Parties hereto have caused this Agreement to be duly executed in duplicate originals as of the month, day, and
year first above written.

 

THE
SERVICE PROVIDER

 

	Signed
    by 	)
	 	 
	CHOO
    CHEE KONG (Singapore National ID: [*****])	)
                                            /s/ CHOO CHEE KONG

    

	 	 
	 	)

 

THE
COMPANY

 

	Signed
    by 	)
	 	 
	TAN
    YOONG YING (NRIC Number: [*****])	)
    /s/ TAN YOONG YING
	 	 
	for
                                            and on behalf of
	)

	 	 
	CYTOMED
    THERAPEUTICS (MALAYSIA) SDN. BHD. (Registration Number: 201301044786 (1074609-M))

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00350-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00350-of-00352.parquet"}]]