Document:

<PAGE>

                                                                   EXHIBIT 10.17

                     EXCLUSIVE SOFTWARE LICENSING AGREEMENT

                                     (JAPAN)

         THIS AGREEMENT is made this 17th day of June, 1999 ("EFFECTIVE
DATE") between C3D Digital, (hereinafter "C3D Digital"), a Utah, U.S.A.
corporation, whose principal place of business is 57 West 200 South #350,
Salt Lake City, Ut, and Software Too Corporation (hereinafter "LICENSEE"), a
business entity incorporated pursuant to the laws of the country of Japan, as
follows:

         WHEREAS, C3D DIGITAL and LICENSEE desire to enter into an agreement
for the supply and license of certain computer software in the country of
Japan;

         NOW, THEREFORE, C3D DIGITAL hereby appoints LICENSEE as an exclusive
Licensee within the country of Japan and all of its legal subdivisions,
territories and possessions according to the boundaries accepted by the
United Nations. The license of the Products hereunder shall be governed only
by the terms and conditions of this Agreement.

     1.  DEFINITIONS

         1.1      Products

              For purposes of this Agreement, Products and defined as any
         software products offered for sale by C3D DIGITAL as specifically set
         forth in the addendum attached hereto as "C3D DIGITAL PRODUCTS LICENSE
         LIST", Addendum A and as modified from time to time by C3D DIGITAL. It
         is intended that the LICENSEE shall have the right to sell all of the
         Products.

         1.2      Localization
              "Localization" is defined as translation of the English language
         version of the document software of the Products into the Japanese
         language.

         1.3      Territory
              "The Territory" is defined as the country of Japan and all of its
         possessions and territories as acknowledged by the United Nations.

         1.4      Computer Program
              "Computer Program" is defined as any instruction or plurality of
         instructions for controlling the operation of a CPU.

         1.5      Customers

                                       175
<PAGE>

              "Customers" are defined as third party customers of LICENSEE who
         purchase and/or receive license for the Products for their own internal
         use or for resale or sublicense in accordance with the terms and
         conditions herein.

         1.6      End Users
              "End Users" are defined as third party customers of LICENSEE or
         LICENSEE's Customers who purchase and/or receive license for the
         Products for their own internal use only.

     2.  ROYALTY  STRUCTURE GOVERNING THE LICENSE

     The royalty structure governing the sale of the products shall be
governed by the addendum entitled "ROYALTY STRUCTURE", Addendum B attached
hereto and incorporated by reference.

     3.  APPOINTMENT

         3.1      LICENSEE'S Obligations
         LICENSEE shall perform in accordance with the terms and conditions set
         forth in " LICENSEE'S DUTIES AND OBLIGATIONS", Addendum C attached
         hereto and incorporated herein by reference.

     4.  ROYALTY PAYMENT

All payments made during the term of this Agreement, or during any renewal
terms, shall be made by LICENSEE to C3D DIGITAL based on the addendem
entitled "ROYALTY STRUCTURE", Addendum B attached hereto and incorporated by
reference via wire transfer to C3D DIGITAL'S bank account at the following
designation:

                                   C3D DIGITAL
                          KeyBank National Association
                            Salt Lake City, Ut 84115

                            Routing Number 124000 737
                           Account Number 440580045092

C3D DIGITAL shall be deemed to have been paid at such time as payment is
irrevocably credited to its bank account.

The price of the Products shall be quoted and fixed in Japanese Yen.

Payment for the price of the Products shall be made in U.S. Dollar which
shall be equivalent to the price of the Products quoted in Japanese Yen at
the date of the delivery of the Products.

Exchange rate for above payment shall be the selling rate of the US Dollars
quoted by Tokyo Mitsubishi Bank at the date of the Royalty report.

                                       176
<PAGE>

5.  Force Majure
Neither party shall be liable for any damages or penalties for delay in
delivery or for failure to give notice of delay when such delay is due to the
elements, acts of God, acts of civil or military authority, fires or floods,
epidemics, quarantine restrictions, war (within the legal borders and/or
international water limits of the Nation(s) in which either Party to this
Agreement is required under the terms of this Agreement to specifically
perform), riots, strikes, lock-outs, or other labor disputes, delays in
transportation, delays in delivery by vendors and any changes in
specifications which are requested by LICENSEE and agreed to by C3D DIGITAL
or any other causes, without limitation, which are beyond the reasonable
control of the delayed party. The delivery date shall be considered extended
by a period of time equal to the time lost as a result of any delay which is
excusable under this clause; provided, however, that such extension shall in
no event exceed one month and in the event the extension period exceeds one
month, LICENSEE may cancel the applicable individual contract.

(s)      RIGHT TO USE THE PRODUCTS

                  Right to Use The Products

         Subject to the terms and conditions of this Agreement, C3D DIGITAL
         hereby grants to LICENSEE the exclusive right to sell, distribute, and
         use the Products.

         6.2      Right to Grant C3D DIGITAL sublicenses to Customers

                  6.2.1  Subject to the terms and conditions of this Agreement,
                  LICENSEE shall facilitate the grant of sublicenses on C3D
                  DIGITAL's behalf to its Customers to use the Software, subject
                  to the terms set out herein.

(vii)    REPORTS AND RECORDS

              1.  Required Records

                           LICENSEE shall keep full, clear and accurate records
                           with respect to all copies of the Products sold.

                  7.1.2  LICENSEE shall furnish to C3D DIGITAL within ten (10)
                  days after the end of each month, a statement setting out
                  sales, inventory levels and any such other material
                  transactions. If there were not transactions during that
                  month, that fact be shown on the report.

                  7.2.2    Right to Audit

                  C3D DIGITAL shall have the right, during LICENSEE'S normal
                  business hours, to have an independent account verify the
                  records of LICENSEE regarding the supply of Products that are
                  reasonably necessary to verify the accuracy of reports issued
                  from Section 7.1.2. The account shall

                                       177
<PAGE>

                  maintain the confidence of such information except to provide
                  C3D DIGITAL with a confirmation of the accuracy of LICENSEE's
                  calculations, or a description of the deviations therefrom.

8.       WARRANTY

         8.1      Software Warranty

                  8.1.1  C3D DIGITAL warrants that it owns and has the right to
                  distribute the Products and grant LICENSEE the right to sell
                  the Products on C3D DIGITAL'S behalf.

                  8.1.2  C3D DIGITAL warrants that the software will conform to
                  the agreed specifications and be free from defects in for a
                  period of one hundred fifty (150) days from the Date of
                  Delivery, or until the time when 90 days have passed from the
                  date on which the Products are or software is delivered to the
                  End Users, whichever is shorter. C3D DIGITAL's only liability
                  under this warranty shall be to repair or replace any such
                  defects.

         8.2      General

                  8.2.1  The above warranties are for the benefit of and shall
                  apply only to LICENSEE.

                  8.2.2  C3D DIGITAL's warranties shall not apply to any defects
                  of the Products, which have has been subjected to accident,
                  neglect, misuse, abuse, vandalism, negligence in
                  transportation or handling, failure of electrical power, air
                  conditioning, humidity control, causes other than ordinary
                  use, or causes beyond C3D DIGITAL's control, or if the
                  Products was not properly maintained by LICENSEE during the
                  warranty period; provided, however that C3D DIGITAL shall have
                  duty to prove the above for its exemption from the warranty
                  obligation.

                  8.2.3  There shall be no warranty or liability for any
                  Products which has been modified by LICENSEE without C3D
                  DIGITAL'Ss prior written approval.

                  8.2.4  The Products outside the scope of these warranties will
                  be furnished at C3D DIGITAL's then current standard charges.

                  8.2.5  C3D DIGITAL shall have full and free access to the
                  Products at LICENSEE's site, subject to the approval of
                  LICENSEE, which shall not be unreasonably withheld.

         8.3      Exclusion of Liability
         There are no warranties, conditions, guarantees or representations as
         to merchantability or fitness for a particular purpose or other
         warranties, conditions, guarantees or representations, whether express
         or implied, oral or in writing, except as expressly stated herein.

                                       178
<PAGE>

9.       LIMITATION OF LIABILITY

         9.1      LICENSEE's Failure
         In no event will C3D DIGITAL be liable for any loss or damage caused by
         LICENSEE's failure to perform LICENSEE'S responsibilities.

         9.2.     Consequential Loss
         C3D DIGITAL shall not, in any event, be liable for any indirect,
         special, emotional or consequential damages, however arising
         (including, but not limited to loss of anticipated profits) in
         connection with or arising out of the furnishing, functioning or use of
         the Products or any item and shall not be liable for any other damages
         except as provided in this Agreement.

         9.3      Time
         Except in respect of the liability of C3D DIGITAL for personal injury,
         no action, regardless of form, arising out of the transactions under
         this Agreement may be brought by LICENSEE more than two (2) years after
         the cause of the action has accrued.

10.      GEOGRAPHIC LIMITATIONS AND COMPETITIVE PRODUCT RESTRICTION

For the duration of this Agreement, LICENSEE agrees that, unless otherwise
specifically authorized in writing by C3D DIGITAL, it will not solicit the
sale, license, or supply the Products, maintain an office or branch for that
purpose, or hold stocks, directly or indirectly sell or inventory the
Products outside the Territory.

11.      INDEMNIFICATION

Except as provided in this Agreement, either party agrees to indemnify and
hold harmless the other party, its agents, employees, successors and assigns
from and against any and all liabilities, losses, damages, claims, suits and
expenses, including legal expenses (including but not limited to attorney's
fees), of whatsoever kind and nature imposed on, incurred by, or asserted
against the other party, its agents, employees, successors and assigns
relating to or arising out of the possession, use, selection, delivery,
purchase, lease or operation of the Products, or any failure on the part of
the first party to perform or comply with the terms of this Agreement.

12.      PATENTS AND COPYRIGHTS
         12.1     Defense and Indemnification
         Subject to the conditions of this clause, C3D DIGITAL agrees that it
         will defend LICENSEE, at C3D DIGITAL's cost and expense, and will
         indemnify and hold harmless LICENSEE, from and against all suits,
         claims, losses, damages and expenses arising from any actual
         infringement of any patent, trademark, or copyright, based upon the as
         a result of import, sale or use of any Products purchased hereunder.

                                       179
<PAGE>

         12.2     Further Representation
         C3D DIGITAL further represents that as of the date of this Agreement,
         no suits, claims or proceedings have been made or instituted against
         C3D DIGITAL alleging that C3D DIGITAL has violated any patent,
         trademark, copyright, registered design, trade secret or other
         proprietary right of any third party in relation to the Products.

         12.3     Notice and Defense
         LICENSEE shall give C3D DIGITAL prompt written notice of any such claim
         or action upon LICENSEE becoming aware of same. In addition, LICENSEE
         shall, at C3D DIGITAL's cost, provide all reasonable assistance in C3D
         DIGITAL's defense or settlement efforts and C3D DIGITAL shall have the
         sole authority to defend or settle such claim.

         12.4     Limitation of Liability
         C3D DIGITAL shall not be liable for any alleged infringement of patent
         or copyright if such infringement is based upon the use of the Products
         in combination with other equipment, software, products, or devices not
         furnished by C3D DIGITAL if such claim would have been avoided but for
         the modification or combination.

         12.5     Entire Warranty
         The foregoing states the entire warranty and liability of C3D DIGITAL
         with respect to any alleged or actual patent, trademark, or copyright
         infringement.

13.      DESIGN CHANGES
Subject to Clause 4.3, C3D DIGITAL reserves the right to make substitutions
and modifications in the specifications of Products to be supplied hereunder.
C3D DIGITAL assumes no obligation to modify or change any Products previously
delivered, or to supply new Products in accordance with earlier
specifications.

14.      DOCUMENTATION
Standard documentation will be supplied by C3D DIGITAL in accordance with C3D
DIGITAL'S Documentation Policy in effect as of the date an Order is accepted
by C3D DIGITAL.

Additional documentation is available under C3D DIGITAL'Ss prevailing terms,
conditions and prices.

15.      TERM AND TERMINATION

         15.1     Term
         This Agreement shall commence upon Effective Date, which shall be the
         day of signing of the agreement. Thereafter, this Agreement shall
         remain in effect for a period of two years from the Effective Date.
         This Agreement may be extended upon written approval of the parties for
         one (1) year. Each such extension shall require written approval.

         15.2     Termination

                                       180
<PAGE>

         Either party may terminate this Agreement at any time by notice in
         writing to the other party, if the other party commits an
         irremediable breach of this Agreement, persistently repeats a
         remediable breach, or commits any remediable breach and fails to
         remedy it within thirty (30) days after receipt of notice of the
         breach. LICENSEE shall be deemed to be in breach if it fails to
         advertise, provide reasonable and adequate technical support or if
         it is supporting or selling a directly competitive product. If the
         other party shall commit an act of bankruptcy, to, or be put into
         liquidation or receivership, pass a resolution for its winding up
         (otherwise than for the purpose of amalgamation or reconstruction),
         or make any assignment for the benefit of its creditors, then the
         other party may terminate this Agreement forthwith upon notice.

         15.3     Other Remedies
         Termination of this Agreement shall be in addition to any other
         remedies which either party may have under this Agreement or otherwise.

         15.4     Results of Termination by C3D DIGITAL

                  15.4.1  In the event that termination is properly effected by
                  C3D DIGITAL under the terms and conditions of this Agreement,
                  no residual rights, except as set forth below, shall remain
                  with LICENSEE hereunder, who shall accordingly be obliged to
                  return to C3D DIGITAL, at LICENSEE's sole cost and expense
                  whatever C3D DIGITAL may request in respect of the Products
                  supplied to LICENSEE hereunder, provided that LICENSEE may
                  sell or dispose of any Products to any third party after such
                  expiration or the termination hereof. On return of the
                  Products, C3D DIGITAL shall repay to the LICENSEE the amounts
                  paid in respect of such Products provided they are new unused
                  and in the same condition as when they left C3D DIGITAL's
                  premises.

                  15.4.2  Upon LICENSEE's default in the payment of monies
                  due in addition to other remedies which may be available,
                  C3D DIGITAL shall be authorized to suspend all deliveries
                  and to cancel any pending individual contract orders, and
                  shall render all pending invoices immediately payable.

         15.5     Expiration of Agreement

         In the event that this Agreement shall expire and LICENSEE is in full
         compliance with all its terms and conditions, LICENSEE shall be
         permitted to continue selling, on C3D DIGITAL'S behalf, its remaining
         inventory of Products, on a non-exclusive basis, upon the terms and
         conditions of this Agreement for a term of six (6) months from the date
         of expiration. The expiration of this Agreement shall not give rise to
         the payment of any indemnity whatsoever by either party to the other.
         In this connection, LICENSEE expressly waives any indemnity for loss of
         clientele, investments not fully amortized, any employee's termination
         indemnities and all advertising and media costs.

         15.6     No Release

                                       181
<PAGE>

         Any expiration and/or termination of this Agreement shall not alter the
         rights, duties and obligations of the parties pursuant to the terms and
         conditions of this Agreement, or for any orders accepted by C3D
         DIGITAL individual contracts entered into prior to the date of such
         expiration and/or termination.

16.      RIGHTS AND CONFIDENTIALITY

         16.1     The Products
         LICENSEE agrees that title and ownership to the Products and
         proprietary rights therein, and any modifications or upgrades thereof
         whether made by C3D DIGITAL or LICENSEE, shall remain exclusively
         with C3D DIGITAL.

         16.2     Proprietary Information
         LICENSEE agrees that all plans, drawings, specifications, and other
         information supplied by C3D DIGITAL to LICENSEE, or derived therefrom,
         including the Products and all information relating to them ("the
         Confidential Information") except for the ones which are already known
         to LICENSEE at the time of disclosure or the ones which are provided by
         any third party, shall remain the property of C3D DIGITAL. LICENSEE
         agrees to use its best efforts (which in any event shall not be less
         than the efforts LICENSEE takes to ensure the confidentiality of its
         own proprietary and other confidential information) to keep any and all
         of the Confidential Information secret and confidential, and shall not
         copy or publish or disclose it to others, or authorize its employees or
         agents or anyone else to copy, publish or disclose it to others, except
         as provided in this Agreement, or with C3D DIGITAL's written approval,
         and shall return such Confidential Information to C3D DIGITAL at its
         request.

         16.3     Duties upon Termination
         Except as provided for herein, upon termination of the License herein
         granted, LICENSEE shall deliver to C3D DIGITAL all material furnished
         by C3D DIGITAL pertaining to the Confidential Information and shall
         not thereafter make any use of it whatsoever.

17.      ASSIGNMENT AND SUBCONTRACTING

         17.1     Assignment by LICENSEE
         This Agreement is personal to LICENSEE, and LICENSEE may not assign or
         transfer any of its rights or obligations under this Agreement without
         the prior written consent of C3D DIGITAL.

         17.2     Assignment by C3D DIGITAL
         C3D DIGITAL may delegate the performance of any of its obligations
         hereunder to any corporation which controls, is controlled or is under
         common control with C3D DIGITAL; provided that C3D DIGITAL shall remain
         liable for performance of the obligations so delegated. In addition,
         C3D DIGITAL may assign its rights to payments due and owing to it
         hereunder.

                                       182
<PAGE>

18.      NOTICE REQUIREMENT

         18.1     Notice to the Bank of Japan
         The parties acknowledge and agree that LICENSEE shall notify the Bank
         of Japan, if it deems the same necessary, pursuant to the Foreign
         Exchange and Foreign Trade Control Law.

         18.2     Notice to the Fair Trade Commission
         The parties further acknowledge and agree that LICENSEE, if LICENSEE
         deems it necessary, shall report the conclusion of the Agreement to the
         Fair Trade Commission within thirty (30) days after the execution
         thereof.

         18.3     Preparation and Submission of Required Notices
         LICENSEE shall prepare the notifications and reports mentioned in the
         prior paragraph. C3D DIGITAL shall cooperate with and assist LICENSEE
         by furnishing all information needed therefor. C3D DIGITAL or its
         agents shall have the right fully participate in all aspects of the
         procedures for preparing such notifications and reports, and shall be
         allowed to examine all documents prior to their submission to the
         appropriate authorities.

         18.4     Notice to C3D DIGITAL
         LICENSEE shall furnish copies to C3D DIGITAL of satisfactory evidence
         of the government notifications and reports made by it pursuant to this
         Article.

19.      GENERAL TERMS AND CONDITIONS

         19.1 No Waiver
         Failure by C3D DIGITAL the party hereto to enforce at any time or for
         any period of time the provisions of this Agreement shall not be
         construed as a waiver of such provisions, and shall in no way affect
         C3D DIGITAL's right to later enforce such provision.

         19.2  Severability
         If any part of this Agreement is determined by any court or tribunal of
         competent jurisdiction to be wholly or partially unenforceable for any
         reason, such unenforceability shall not affect the remaining parts of
         this Agreement.

         19.3  Remedies
         All rights and remedies conferred under this Agreement or by any other
         instrument or law shall be cumulative and may be exercised singularly
         or concurrently.

         19.4  Independent Third Party

                                       183
<PAGE>

         LICENSEE is not and will not hold itself out as the representative,
         agent, commission-sales agent, servant or employee of C3D DIGITAL for
         any purpose. This Agreement creates no relationship of joint venture,
         partnership, limited partnership, or agency between the parties, and
         the parties hereby acknowledge that no other facts or relations exist
         that would create any such relationship between them. Neither party has
         any right or authority to assume or to crease any obligation or
         responsibility on behalf of the other party except as may from time to
         time be provided by written instrument signed by both parties.

         19.5  Headings
         The headings contained in this Agreement are for convenience only and
         shall not affect the interpretation or meaning of this Agreement.

         19.6  Survival
         Notwithstanding the expiration or termination of this Agreement or any
         renewal period hereof, it is acknowledged and agreed that those rights
         and obligations which by their nature are intended to survive such
         expiration or earlier termination shall survive.

         19.7  Entire Agreement

         This Agreement constitutes the entire agreement between the parties and
         supersedes all prior agreements, understandings and negotiations with
         respect to the subject matter thereof. This Agreement may not be
         changed or modified except by a written instrument duly executed by
         each of the parties hereto.

         19.8  Law, Jurisdiction, Arbitration

                  19.8.1   Governing Law
                  The formation, validity, construction and performance are
                  governed by statutory, decision or other laws of the State of
                  Utah, United States of America, as of the date hereof.

                  19.8.2   Arbitration
                  All disputes, controversies or differences which may arise
                  between the parties hereto, out of or in relation to or in
                  connection with this Agreement, or for any breach hereof,
                  shall be settled by arbitration in Salt Lake City, Utah,
                  U.S.A.
                  The "appointing authority" provided for in said rule shall
                  be the American Arbitration Association. The prevailing
                  party in any such arbitration shall be entitled to an award
                  of costs and attorneys' fees.

                  1        Jurisdiction
                  In the event litigation shall, for any reason, ensue between
                  the parties in connection with this Agreement, the exclusive
                  forum and jurisdiction shall be the U.S. Federal District
                  Court of Utah, Salt Lake City, Utah, U.S.A..

                                       184
<PAGE>

20.      NOTICES

All notices required or desired to be given hereunder shall be in writing and
if not personally delivered, be sent by telex or facsimile (with a copy by
ordinary mail) or by registered or recorded delivery. If faxed or personally
delivered, notices shall be deemed to have been given on the day when
personally delivered or faxed, addressed to the other party at the address
for service specified herein, provided that either party may from time to
time change the address to which notices to it are to be sent by giving
notice of such change to the other party. If mailed by registered or
certified mail, notices shall be deemed to have been given when received
unless otherwise specifically stated.

Mail To: C3D Digital, Inc.
Attn: Dennis Derrick
567 South Valley View Drive
St. George, Utah 84770

Mail To: Software Too
         Attn:

LICENSEE acknowledges that it has read and agrees to the terms and conditions
contained in this Agreement.

IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be
signed by their duly authorized representatives as of the date set forth
below.

DATED this 17th day of June, 1999.

 /s/ Dennis Derrick
-------------------------------------------
Dennis Derrick, Vice President
3D.COM (A subsidiary of C-3D Digital, Inc.)

SOFTWARE TOO CORP.

 /s/
---------------------

                                       185
<PAGE>

                                   Addendum A

C3D DIGITAL PRODUCTS LIST

                                       186
<PAGE>

                                   Addendum B

ROYALTY STRUCTURE

LICENSEE shall compensate C3D DIGITAL as follows:

I.       ROYALTY:

LICENSEE agrees to guarantee $96,000 a month for six months from the signing
of this agreement. Any sales above $96,000 shall go to pay down the current
inventory credit outlined in Addendum D. C3D DIGITAL shall receive royalty
payments based on the following: 10,000 minimum payment. Any sales above the
minimum payments shall go to pay down the current inventory credit.

A.  General License
Thirty percent (30%) of the Japan list price (Yen) on localized and English
language version sold through channels (i.e., stores and middlemen).

B.  Sales to Educational Institutions
Thirty Five percent (35%) of the Japan list price (Yen) on localized and
English language version sold to accredited academic institutions.

C.  Direct Sales to End Users
Thirty Five percent (35%) of the Japan list price (Yen) on localized and
English language version sold to End Users.

D.  Market Development Fund
An additional Five percent (5%) shall be made available 2 years or until this
fund pays $150,000.

II.      BUNDLING:

The parties recognize that circumstances may arise in which either LICENSEE
or C3D DIGITAL may choose to bundle the Products with other software, or C3D
DIGITAL may choose to bundle the Product with third-party hardware Products.
It is agreed that, in such event, the discounts to be paid to LICENSEE C3D
DIGITAL will be determined on a case-by-case basis. The parties acknowledge
that each such bundling arrangement may differ sufficiently that a standard
discount cannot be set in this Agreement. Accordingly, the parties agree to
negotiate in a good faith and commercially reasonable manner to determine the
appropriate discount amount.

                                       187
<PAGE>

                                   Addendum C

LICENSEE'S DUTIES AND OBLIGATIONS OUTLINES

1.   Maintain adequate experienced personnel and facilities, as follows: .

2.   Use best efforts to promote supply of products within the Territory,
     as follows: .

3.   Provide technical support, as follows:

     __First call support level, like installation instruction, etc.

     -----------------------------------------------------------------------

     -----------------------------------------------------------------------

                                       188
<PAGE>

                                   Addendum D

INVENTORY CREDIT

C3D Digital agrees to grant LICENSEE a credit of $945,042.26 for the returned
inventory units stocked as of March 31, 1999 at LICENSEE's warehouse. The
list of returned units is attached as Attachement 1.

The credit shall be paid down with the royalty amounts that exceed the
monthly guarantees as defined in Addendum B.

                                       189<PAGE>

                                                                   EXHIBIT 10.18

                                BE, INCORPORATED.
                BEDEPOT ON-LINE ORDER AND DISTRIBUTION AGREEMENT

         This BeDepot On-Line Order and Distribution Agreement (the
"Agreement") is made as of May 17, 1999 between Be, Incorporated, a
California corporation, having a place of business at 800 El Camino Real,
Suite 400, Menlo Park, CA 94025 ("Be, Inc."), and Strata , a Utah
corporation, having a place of business at 567 South Valley View Drive, Suite
202, St. George, Utah 84770 ("Developer").

         In consideration of the mutual promises contained in this Agreement,
the parties agree as follows:

1.   DEFINITIONS.  THE FOLLOWING TERMS SHALL HAVE A DEFINED MEANING AS USED
IN THIS AGREEMENT:

         1  "END USER" means a licensee of computer products who acquires
such products for personal or ordinary business usage and not for further
distribution or resale.

         2  "END USER AGREEMENT" means Developer's applicable on-line
electronic end user license agreement accompanying each Product, including
the PackageBuilder license provided by Be, Inc. as incorporated by the
Developer into the Developer's electronic agreement, in the format provided
in Section 4.2 of this Agreement.

         3  "PRICE LIST" means Developer's suggested retail price list for
the Products as set forth in EXHIBIT A ("Price List"), as amended from time
to time upon notice by Developer to Be, Inc.

         4  "PRODUCTS" means physical merchandise; including books and
clothing, and Developer's software products (in object code form only)
("Software Products"); including commercial, free, trial, demonstration, and
update versions; together with supporting End User documentation
("Documentation"), all as identified in the Price List.

         5  "BEDEPOT WEBSITE" means the Internet site located at
http://www.bedepot.com or any alternative or successor site designated by Be,
Inc. from time to time.

         6  "LAUNCH/RELEASE/UPDATE" means the initial public availability of
a product through the BeDepot Internet web site. This includes all versions
of Products including launches of completely new Products, releases of new
versions of existing Products, and minor updates or fixes to existing
Products.

2.   RIGHTS OF BE, INC.

         1  LICENSE GRANT TO BE, INC.  During the term of this Agreement and
subject to the terms and conditions set forth therein, Developer hereby
grants Be, Inc. a nonexclusive, worldwide, royalty-free, irrevocable,
fully-paid up license to:

               Reproduce, and have reproduced, publicly display, publicly
         perform and, solely as a means to aid in the

                                       190
<PAGE>

         electronic delivery of the Products, modify the Products identified
         in the Price List.

               Distribute, or have distributed, electronically or otherwise,
         the Products, either on a stand-alone basis or bundled with other
         Products or products of other Be, Inc. developers, to End Users who
         order the Products from the BeDepot Website.

               Use, in accordance with Developer's reasonable policies
         regarding advertising and trademark usage as established from time
         to time and provided to Be, Inc., Developer's trademarks, trade
         names, and logos (collectively, the "Trademarks") in Be, Inc.'s
         distribution, advertising and promotion of the Products on the
         BeDepot Website. Be, Inc. agrees that it shall not use any other
         trademark, word, letter, design or mark (i) in combination with the
         Trademarks in a manner that would create a combination mark or (ii)
         that is confusingly similar to the Trademarks; provided, however,
         that Be, Inc. may use the Trademarks with other marks or names if
         such other marks or names are sufficiently separated from the
         Trademarks and sufficiently distinctive to avoid the consumer
         impression that such other marks or their owners are associated with
         Developer. Be, Inc. agrees not to register any Developer trademarks.
         Be, Inc. agrees to cooperate with Developer in facilitating
         Developer's monitoring and control of the nature and quality of such
         products and services, and to supply Developer with specimens of use
         of the Trademarks upon request.

               Use the Products for demonstration and testing purposes
         subject to the terms and conditions of the applicable End User
         Agreement.

         2     Restrictions

               Ownership of Proprietary Rights.  Be, Inc. acknowledges that
         any Software Product and its sequence, structure and organization is
         proprietary to Developer and that Developer retains exclusive
         ownership of the Trademarks and any Software Product.  Be, Inc. will
         take all reasonable measures to protect Developer's proprietary
         rights in any Software Products.  Except as provided herein, Be,
         Inc. is not

                                       191
<PAGE>

         granted any rights to patents, copyrights, trade secrets, trade
         names, trademarks (whether registered or unregistered), or any other
         rights, franchises or licenses with respect to any Products.

               Restrictions on Copying and Reverse Engineering. Be, Inc.
         agrees not to reproduce, copy, modify, translate, disassemble,
         reverse engineer or otherwise attempt, or permit others to attempt,
         to discover the source code of the Software Products, in whole or in
         part.  However, Developer acknowledges and agrees that while Be,
         Inc. will use commercially reasonable efforts to preserve the
         proprietary rights of the Software Products, Be, Inc. cannot make
         any warranties regarding the protection of the Software Products
         during and after the electronic download thereof from the BeDepot
         Website.  Be, Inc. will have no liability for any unauthorized use
         of the Software Products by any End User.

         3  PRODUCT DELIVERY.  Developer agrees that Be, Inc. shall receive
each new commercial Product (i.e. the initial release of a Product as well as
major or minor updates and trial or demonstration versions of any Product) no
later than 48 hours after such Product is made generally available by
Developer.

3.   DELIVERY OF PRODUCTS AND OTHER MATERIALS.

         1  PRODUCTS FOR DISTRIBUTION VIA DOWNLOAD FROM BEDEPOT.  Within ten
(10) days after the Effective Date of this agreement, Developer shall deliver
to Be, Inc. the current version(s) of the Product(s) on the Price List
(Exhibit A) that are to be distributed via electronic download from Be,
Inc.'s web site, BeDepot, and the applicable End User Agreement for such
Products. With regard to the initial delivery, deliveries of new Products and
upgrades, and delivery of the End User Agreement, Developer will provide Be,
Inc. with a copy of the Product through electronic mail or via a file
transfer protocol agreed to by Be. Inc. prior to delivery of each Product.

         2  PHYSICAL DISTRIBUTION THROUGH ALOM TECHNOLOGIES.  Developer is
responsible for establishing and maintaining an inventory relationship
(including payment of all associated fees) with ALOM Technologies ("ALOM").
Within ten (10) days after the Effective Date of this Agreement, Developer
agrees to deliver to ALOM an initial delivery of all Products that are to be
ordered by End Users via BeDepot but that are to be physically distributed by
ALOM. Developer will at all times use its best efforts, consistent with
prudent business practice, to maintain a representative inventory of Products
and upgrades in reasonably sufficient quantities to provide adequate and
timely delivery to End Users. Developer agrees that title of the Product, but
not the risk of loss, shall pass to Be, Inc. upon commencement of order
fulfillment by ALOM Technologies. Developer also agrees that Be, Inc.
reserves the right to return title of Product to Developer in case of damage
during shipment, return by End User, or at it's sole discretion.

         3  OTHER MATERIALS.  Developer will provide Be, Inc. with the
materials necessary to create a web page on the BeDepot web site as specified
in Section 6 of this Agreement ("Joint Marketing"), as well as any
information Be, Inc. will need to conform to California laws regarding
disclosure of information in relation to the sale of Developer's Product(s).
Developer will provide these materials on CD-ROM or through electronic mail
or via a file transfer protocol agreed to by Be. Inc. with

                                       192
<PAGE>

reasonably adequate lead times to allow Be, Inc. to format and post such
materials on the BeDepot web site prior to the date Developer's Products are
to be made available for purchase. With regard to the initial delivery of all
new Products and upgrades for any method of distribution, Developer will
provide Be, Inc. with (i) a copy of the Product on CD-ROM or through
electronic mail or via a file transfer protocol agreed to by Be. Inc. prior
to delivery of each Product, (ii) Product specification information in HTML
format, or in another mutually agreeable computer readable form that can be
reproduced by Be, Inc., and (iii) Additional electronic copy of the End-user
license agreement separate from the Product in text (.txt) format, or in
another mutually agreeable computer readable form that can be reproduced by
Be, Inc.

4.   SALE TERMS AND PAYMENT.

         1  ORDERS AND PAYMENT BY END-USERS.  Be, Inc. shall accept orders
for Products from End Users through the BeDepot Website. Be, Inc. also
reserves the right at its sole discretion to accept orders for Products from
End Users through telephone, facsimile, postal mail, or electronic mail. In
the case of physical delivery, Be, Inc. reserves the right to stop taking
orders for a product if the inventory for that product is depleted; Be, Inc.
has no obligation to take back orders. Be, Inc. reserves the right to charge
additional fees to customers for services involved in the sale of the
product, such as shipping, tax, miscellaneous processing fees, etc.

         2  END USER AGREEMENTS.  Developer will include in the Product's
start-up routine a mechanism, such as a click-through procedure, whereby the
End User must again affirmatively assent to the End User Agreement. The terms
and conditions of such End User Agreement shall in no way conflict with the
terms as set forth in this Agreement. In addition, Developer will include in
its End User Agreement a provision substantially similar to the following
paragraph, authorizing the use of the End User's copy of Software Valet to
obtain upgrades, patches or any other form of software update automatically
using the End User's computer and connection to the Internet.

               "The Software is designed for use with the Be Incorporated
               Software Valet product which automatically provides
               application and registration information to and obtains
               upgrades, patches and updates for the Software from the
               BeDepot world wide web site using your computer and connection
               to the Internet. In light of such design, you hereby
               acknowledge and authorize the aforementioned use when
               installing and using the Software."

         Be, Inc. shall have no responsibility for preparing any End User
Agreements on Developer's behalf.

         3  PRICE AND PAYMENT.  Developer agrees that the Products will be
offered to End Users at prices set by Be, Inc. in its sole discretion. In
consideration for the grant of the license to distribute the Products
hereunder, Be, Inc. shall pay Developer the price listed on the Price List
for each copy of the Product sold to End Users through the BeDepot Website.
Developer, at its option, may occasionally provide Products to Be, Inc. at
prices that are lower than the prices set forth on the Price List for limited
times in connection with Developer promotions and bundles. If Be, Inc. agrees
to participate in such promotions, for the duration of such promotions or
bundles, Be, Inc. agrees to offer Developer's Product(s) to End Users at
prices that reflect the promotional discounts Be has received. If Developer
and Be, Inc. agree to change the price listed on the Price List for any
reason, a Price List Amendment form must be submitted in writing and signed
by both Developer and Be, Inc.

         Developer agrees to offer its Product(s) to Be, Inc. at a price that
is at least as low as the lowest price Developer charges other resellers.
Developer agrees that it will not sell any Product to End Users at a price
that is lower than the price then charged for the same Product on the BeDepot
Website.

                                       193
<PAGE>

         4  PRODUCT AVAILABILITY.  New products shall be deemed "Products"
when Developer adds them, and Be agrees to have them added, to the Price
List. Developer has the right to discontinue the distribution or availability
of any Product upon sixty (60) days prior written notice to Be, Inc.

         5  TAXES AND DUTIES.  Be, Inc. shall be responsible for any federal
or local sales, use, excise, or similar tax other than those based on
Developer's net income (collectively the "Taxes") and any penalties or
interest associated with any of the Taxes, imposed by any governmental
authority with respect to any payment received or made by Be, Inc. under this
Agreement or any Product to be delivered by Be, Inc. to End Users under this
Agreement. Notwithstanding the foregoing, BeDepot is not responsible for any
customs fees or Value Added Taxes. Developer will provide Be, Inc. with all
reasonably requested assistance in order for Be, Inc. to comply with its Tax
obligations hereunder; provided, however, that upon Developer's request, Be,
Inc. agrees to sign an appropriate confidentiality agreement preserving the
proprietary nature of any such information.

         6  PAYMENT TERMS.  Be, Inc. shall send payment to Developer within
thirty (30) days after the end of each month for all Product sales for which
Be, Inc. has received payment in such month, less the amount returned to End
Users based on Product refunds allowable under this Section 4 of the
Agreement in that month or any previous month. Be, Inc. will send payment via
the U.S. Postal Service. Any fees incurred from the use of any mutually
agreed upon alternative delivery method will be charged to Developer.

         7  REFUND POLICY FOR PRODUCTS DELIVERED ELECTRONICALLY.  Be, Inc.
will provide End Users with a thirty (30) day money-back guarantee policy for
each Product designated by Developer. End Users shall be entitled to receive
a refund of the Product purchase price within thirty (30) days after
downloading the Product notwithstanding that the Product is not functionally
defective or otherwise fails to qualify for warranty service under the
applicable End User Agreement. Developer agrees that Be, Inc. shall receive
credit for any Product returns through the adjustment of the monthly Be, Inc.
payment to Developer for the period during which the Product returns occur.
Be, Inc. shall have no obligation to refund to Developer any of the
transaction costs it collects from the sale of Products which are
subsequently returned by End Users either in connection with the thirty (30)
day money-back guarantee or a provision of the Developer's End User Agreement.

         8  REFUND POLICY FOR PRODUCTS DELIVERED PHYSICALLY.  Be, Inc. will
provide the same thirty (30) day money-back guarantee for Products delivered
physically as is offered in Section 4.7 of this Agreement. Developer agrees
that Be, Inc. shall be credited for any Product returns through adjustment of
the monthly Be, Inc. payment to Developer for the period during which the
Product returns occur. Be, Inc. reserves the right to dispose of or return to
Developer, at Developer's option, returned Product(s), regardless of
condition. Be, Inc. reserves the right, but is not obligated, to charge
Developer for costs related to returns of their products, whether such
returns are in connection with the thirty (30) day money-back guarantee or a
provision of the Developer's End User Agreement. Be, Inc. shall have no
obligation to refund to Developer any of the transaction costs it collects
from the sale of Products which are subsequently returned by End Users either
in connection with the thirty (30) day money-back guarantee or any provision
of the Developer's End User Agreement.

5.   BE, INC. OBLIGATIONS.

         1  END USER REGISTRATION.  End Users will have the option to
register their use of a Product with Be, Inc. via a designated registration
service (i.e. SoftwareValet or any substitute service designated by Be, Inc.)
("Registration Service") and information related solely to the End User's
purchase of the Products that is received by Be, Inc. from such registration
will be forwarded to Developer, if such End User has authorized Be, Inc.'s
disclosure of such information to Developer. End Users that elect to register
will be required to provide, at a minimum, their name and e-mail address and
at their option, address, company name and facsimile number.

                                       194
<PAGE>

         2  END USER INFORMATION.  Be, Inc. and, if such End User so agrees,
Developer, each have rights to the information gathered through the
designated registration service. Developer does not have rights to, nor will
it receive, information provided by the End User for sale transaction
administration, or information in connection with any purchase other than
that of the Products. Be, Inc. does not guarantee the accuracy of the
information collected during registration and forwarded to Developer.

         3  RECORDS AND REPORTS.  Be, Inc. shall provide Developer a monthly
report of Product distributions that include the amounts paid to Developer
and the prices charged by Be, Inc. Such report shall be provided with the
monthly payment from Be, Inc. to Developer. Be, Inc. agrees to maintain
complete, clear and accurate records of Product distributions. Not more than
once in any twelve (12) month period, Be, Inc. shall permit an independent
auditor designated by Developer and reasonably approved by Be, Inc. to
inspect records pertaining to the Products and any other materials provided
to Be, Inc. by Developer to ensure compliance by Be, Inc. with its
obligations to Developer. Any such inspection and audit shall be conducted
during regular business hours and in such a manner as not to interfere unduly
with normal business activities of Be, Inc.

         4  PRODUCT MAINTENANCE AND SUPPORT.  Be, Inc. will provide End Users
with the relevant support contact information from EXHIBIT B ("Contact
Information") in order that End Users may obtain maintenance and support
directly from Developers. Be, Inc. shall have no obligation to provide any
maintenance or support to any End User except in the case of minor updates
and bug fixes which may be delivered to End Users by Internet download. This
Agreement must be in effect at the time an End User requests any such update
or bug fix. Any additional Be, Inc. services shall also be subject to an
additional fee to be agreed upon between Be, Inc. and Developer.

         5  PRODUCT LAUNCHES/RELEASES/UPGRADES.  Developer is allowed a total
of three (3) free Launches, Releases, or Upgrades in any three (3) month
period for any Product Developer has on the Price List. Developer agrees to
pay Be, Inc. two hundred and fifty dollars ($250) for each additional Launch,
Release or Upgrade of a Product on the Price List.

         6  WEBSITE AVAILABILITY.  Be, Inc. intends to make Products
available on the BeDepot Website seven (7) days a week, twenty-four (24)
hours a day, except for scheduled maintenance and required repairs, and
except for any loss or interruption of service due to causes beyond the
control of Be, Inc. or which is not reasonably foreseeable by Be, Inc.,
including but not limited to, interruption or failure of telecommunication or
transmission links. However, occasional website downtime should be
anticipated and Be, Inc. does not warrant that the BeDepot Website will be
functioning or available at all times.

         7  ORDER SUPPORT.  Be, Inc. will provide technical support to End
Users and prospective End Users during the downloading and installation
process Monday through Friday, 9:00 a.m. to 5:00 p.m., Pacific Time. Be, Inc.
shall have the right to allow an End User to download a product more than
once if Be, Inc. determines that the first download was not completed
successfully. Be, Inc. will provide End Users with the contact information
for the Complaint Assistance Unit of the Division of Consumer Services of the
Department of Consumer Affairs of the State of California in the event they
have any questions or concerns regarding the services provided by the BeDepot
Website.

6.  JOINT MARKETING.  For each Product distributed by Be, Inc. hereunder, Be,
Inc. will provide a web page on the BeDepot Website with a product
description, a screenshot from the Product, a hyperlink to Developer's
website and contact information for the Developer. These items shall be
provided by Developer to Be, Inc. in the format designated in Section 3 of
this Agreement ("Delivery of Products and Other Materials to Be, Inc.").

                                       195
<PAGE>

         Developer agrees to identify Be, Inc. and the BeDepot Website as an
authorized distributor of the Products in all press releases related to the
Products to the extent that Developer identifies its other distributors in
press releases. Developer agrees to include a hyperlink from the Developer's
web site to the BeDepot Website. Furthermore, Be, Inc. may identify Developer
and its Products, including use of Developer's trademarks, in all its press
releases promoting the BeDepot Website and Be, Inc.'s business.

         Be, Inc. reserves the right to remove or modify any images or text
it deems obscene, libelous, inappropriate or otherwise unsuitable for
commercial use and distribution.

7.  TERM.  The term of this Agreement shall commence as of the date of this
Agreement and continue for one (1) year from the Effective Date. Thereafter,
this Agreement shall renew automatically for successive one (1) year periods
unless a party provides written notice to the other of nonrenewal at least
sixty (60) days prior to the end of the then current term.

8.   WARRANTIES.

         1  PRODUCT.  Developer warrants the Products to End Users only
pursuant to the terms and conditions of the End User Agreement or warranty
card and no warranty is extended to Be, Inc. except as provided in this
Agreement. The currently applicable End User warranty terms are set forth in
the End User Agreement and are subject to change from time to time in
Developer's discretion. Developer agrees to provide Be, Inc. with written
notice of any change in the End User Agreement and a copy of the new
agreement in the format specified in Section 3 in order that Be, Inc. may
display the new End User Agreement to End Users on the BeDepot Website. Be,
Inc. will display the new End User Agreement, and its terms will become
effective against users, thirty (30) days after Be, Inc. receives the new
Agreement in the specified format.

         2  PACKAGEBUILDER LICENSE:  Developer represents and warrants that
(i) each Product has been developed with Be, Inc.'s PackageBuilder product
("PackageBuilder") pursuant to Be, Inc.'s electronic license agreement (the
"PackageBuilder License") and (ii) Developer has read and agrees to the terms
and conditions of the PackageBuilder License.

         3  CONTENT.  Developer warrants that the Product(s) and marketing
materials it submits to Be, Inc.: (a) shall not infringe any third party's
copyright, patent, trademark, trade secret or other proprietary rights or
rights of publicity or privacy; (b) shall not violate any law, statute,
ordinance or regulation (including without limitation the laws and
regulations governing export control, unfair competition, anti-discrimination
or false advertising); (c) shall not be defamatory, trade libelous,
unlawfully threatening or unlawfully harassing; (d) shall not be obscene,
pornographic or indecent or contain child pornography; and (e) shall not
contain any viruses, trojan horses, worms, time bombs, cancelbots or other
computer programming routines that are intended to damage, detrimentally
interfere with, surreptitiously intercept or expropriate any system, data or
personal information.

         4  NO OTHER OBLIGATIONS.  Be, Inc. will have no other warranty or
maintenance obligations other than as expressly set forth in this Agreement
unless it has entered into a written agreement therefor with Developer.

         5  LIMITATIONS AND DISCLAIMER OF WARRANTIES AND CONDITIONS.  EXCEPT
FOR THE EXPRESS WARRANTIES AND CONDITIONS SET FORTH ABOVE, NEITHER PARTY
MAKES ANY OTHER WARRANTIES OR CONDITIONS RELATING TO THE PRODUCTS OR SERVICES
PROVIDED HEREUNDER, EXPRESS OR IMPLIED AND EXPRESSLY EXCLUDES ANY WARRANTY OF
FITNESS FOR A PARTICULAR PURPOSE OR MERCHANTABILITY. NO

                                       196
<PAGE>

PERSON IS AUTHORIZED TO MAKE ANY OTHER WARRANTY, CONDITION OR REPRESENTATION
CONCERNING THE PERFORMANCE OF THE PRODUCT OTHER THAN AS PROVIDED IN THIS
SECTION 8 ("Warranty") AND IN THE END USER AGREEMENT. BE, INC. SHALL MAKE NO
OTHER WARRANTY OR CONDITION, EXPRESS OR IMPLIED, ON BEHALF OF DEVELOPER.

9.   INDEMNITY.

         1  DEVELOPER INDEMNITY.  Developer shall defend and indemnify Be,
Inc. against any claim, suit or proceeding (including reasonable attorneys'
fees) arising from product liability claims or alleging that a Product or any
marketing materials infringe a patent, copyright, trademark or trade secret.
The foregoing obligation is subject to Be, Inc. (i) giving Developer prompt
written notice of any such claim; (ii) allowing Developer to control the
defense and settlement of such claim; (iii) not entering into any settlement
or compromise of such claim without Developer's prior written consent; and
(iv) providing all assistance reasonably requested by Developer in the
defense or settlement of such claim, at Developer's expense. Upon notice of
an alleged infringement or if in Developer's opinion such a claim is likely,
Developer shall have the right, at its option, to obtain for Be, Inc. the
continuing right to distribute the Product, substitute other non-infringing
computer software with similar operating capabilities or modify the Product
so that it is no longer infringing. In the event that none of the above
options are reasonably available in Developer's opinion, Be, Inc.'s sole and
exclusive remedy shall be to terminate this Agreement.

         2  BE, INC. INDEMNITY.  Be, Inc. shall be responsible for any
claims, warranties or representations made by Be, Inc. or Be, Inc.'s
employees or agents which differ from the warranty provided by Developer in
its End User Agreement. The foregoing obligation is subject to Developer (i)
giving Be, Inc. prompt written notice of any such claim; (ii) allowing Be,
Inc. to control the defense and settlement of such claim; (iii) not entering
into any settlement or compromise of such claim without Be, Inc.'s prior
written consent; and (iv) providing all assistance reasonably requested by
Be, Inc. in the defense or settlement of such claim. The foregoing sets forth
Developer's sole and exclusive remedy for any such claim.

10.  TERMINATION.

         1  WITH CAUSE.  Either party may terminate this Agreement upon
thirty (30) days written notice of a material breach of this Agreement by the
other party if such breach is not cured within such thirty (30) day period.

         2  FOR CONVENIENCE.  Either party may terminate this Agreement for
convenience upon sixty (60) days written notice to the other party.

         3  RIGHTS UPON TERMINATION.  After notice of termination but prior
to the effective termination date, Be, Inc. shall be entitled to accept
orders for Products from End Users and fulfill such orders notwithstanding
that the fulfillment of and payment for such orders may extend beyond the
effective termination date. Each party shall be entitled to all payments
provided for under this Agreement for such orders. Be, Inc. shall pay all
amounts due to Developer within ninety (90) days after the effective
termination date.

         4  SURVIVAL.  The following provisions survive expiration or
termination of this Agreement: 2.2 ("Restrictions"), 4 ("Terms"), 8
("Warranty "), 9 ("Indemnity"), 10.3 ("Rights upon Termination"), 11
("Consequential Damages Waiver"), 12 ("Limitation of Liability") and 13
("Miscellaneous").

11.  CONSEQUENTIAL DAMAGES WAIVER.   NEITHER PARTY WILL BE LIABLE FOR ANY
LOSS OF USE, INTERRUPTION OF BUSINESS, OR ANY EXEMPLARY, SPECIAL, INCIDENTAL
OR CONSEQUENTIAL DAMAGES OF ANY KIND (INCLUDING LOST PROFITS)

                                       197
<PAGE>

REGARDLESS OF THE FORM OF ACTION WHETHER IN CONTRACT, TORT (INCLUDING
NEGLIGENCE) AND STRICT PRODUCT LIABILITY OR OTHERWISE, EVEN IF A PARTY HAS
BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES.

12.  LIMITATION OF LIABILITY.  NOTWITHSTANDING ANY OTHER PROVISIONS OF THIS
AGREEMENT, EACH PARTY'S AGGREGATE LIABILITY TO THE OTHER UNDER THIS AGREEMENT
SHALL BE LIMITED TO THE AMOUNT EQUAL TO THE TOTAL PAYMENTS MADE BY BE, INC.
TO DEVELOPER IN THE TWELVE (12) MONTHS PRIOR TO THE DATE A CLAIM FIRST
ARISES. BE, INC. SHALL HAVE NO LIABILITY FOR ANY PERFORMANCE OR FAILURE OF
THE BEDEPOT WEBSITE TO PERFORM OR FUNCTION AT ANY GIVEN TIME.

13.  MISCELLANEOUS.

         1  NOTICES.  Any notices permitted or required under this Agreement
shall be in writing, and shall be delivered in person or by certified or
registered mail, return receipt requested, and shall be deemed given upon
personal delivery or five (5) days after deposit in the mail. In the event a
Developer has any concerns about the services offered by the BeDepot Website
which are not addressed by Be, Inc., Developer may contact the Complaint
Assistance Unit of the Division of Consumer Services of the Department of
Consumer Affairs of the State of California.

         2  ASSIGNMENT.  This Agreement may not be assigned by either party
without the prior written approval of the other party, which approval will
not be unreasonably withheld. A change in the persons or entities who control
fifty percent (50%) or more of the equity securities or voting interest of a
party through a reorganization, merger, consolidation or reincorporation or a
sale of all or substantially all of the assets of a party shall not be
considered an assignment for which prior written approval is required.

         3  WAIVER.  The waiver by either party of a breach of any provisions
contained herein shall be in writing and shall in no way be construed as a
waiver of any succeeding breach of such provision or the waiver of the
provision itself.

         4  SEVERABILITY.  In the event that any provision of this Agreement
is determined to be unenforceable or invalid under any applicable law or be
so held by applicable court decision, such unenforceability or invalidity
shall not render this Agreement unenforceable or invalid as a whole, and, in
such event, such provision shall be changed and interpreted so as to best
accomplish the objectives of such provision within the limits of applicable
law or applicable court decisions.

         5  CONTROLLING LAW.  This Agreement shall be governed in all
respects by the laws of the State of California and the United States of
America as such laws are applied to agreements entered into and to be
performed entirely within California between California residents. The United
Nations Convention on the International Sale of Goods is hereby expressly
excluded from application to this Agreement. All disputes arising under this
Agreement may be brought in Superior Court of the State of California in
Santa Clara County or the Federal District Court of San Jose and the parties
hereby submit to the non-exclusive jurisdiction of such courts.

         6  NO AGENCY.  Nothing contained herein shall be construed as
creating any agency, partnership, or other form of joint enterprise between
the parties.

         7  EXPORT.  Developer acknowledges that the laws and regulations of
the United States may restrict the export and re-export of certain
commodities and technical data of United

                                       198
<PAGE>

States origin. Developer represents and warrants that none of the Products
are subject to any United States or foreign restrictions on export or
re-export and Be, Inc.'s distribution of the Products as contemplated by this
Agreement does not require any United States or foreign licenses or permits.
To the extent that any such permits or licenses are required, Developer
agrees to give prompt advance notice thereof to Be, Inc. and obtain such
permits and licenses at Developer's sole cost and expense. Be, Inc. agrees to
provide all reasonably requested assistance to Developer, at Developer's sole
cost and expense, to obtain such permits and licenses.

         8  COUNTERPARTS.  This Agreement may be signed in two counterparts
which together shall form a single agreement as if both parties had executed
the same document.

         9  ENTIRE AGREEMENT.  This Agreement (including all attached
Exhibits) completely and exclusively states the Agreement of the parties
regarding its subject matter. It supersedes, and its terms govern, all prior
or contemporaneous proposals, agreements or other communications between the
parties, oral or written, regarding such subject matter. This Agreement shall
not be modified except by a subsequently dated written amendment signed on
behalf of Developer and Be, Inc. by their duly authorized representatives.

         10  WARRANTY.  Each party warrants that it has full power and
authority to enter into and perform this Agreement, and the person signing
this Agreement on each party's behalf has been duly authorized and empowered
to enter into this Agreement.

         IN WITNESS WHEREOF, the parties hereto have caused this Agreement to
be executed by their duly authorized representatives as of the date first
written above.

BE, INCORPORATED                             DEVELOPER

Signed: /s/ J.R. Graham                       Signed: /s/ Dennis Derrick
       -------------------------------              ----------------------------
Name:     J.R. Graham                        Name:     Dennis Derrick

Title:    Sales and Marketing                Title:    Vice President

                                       199
<PAGE>

                                    EXHIBIT A

                                   Price List

<TABLE>
<CAPTION>
        Product Name                       Type              Delivery               SRP             BeDepot Cost
-----------------------------       ------------------   -----------------    ---------------  -----------------------
<S>                                 <C>                  <C>                  <C>              <C>

</TABLE>

NOTES:

    Product Name - The defining name of the product. (I.E. Software products
    should have name and version numbers, clothing should have name, color,
    style and size)

    Type - Should be one of the following three: 1) Software 2) Book 3)
    Merchandise

    Delivery - Should be one of the following two: 1) Electronic (I.E. Internet
    download of software only) 2) Physical (I.E. Ship through the mail)

    SRP - The suggested retail price for the particular version of the Product
    determined by the Developer. The suggested retail price for the electronic
    delivery version (I.E. Internet download) of a software Product is typically
    10% to 20% less than the box version.

    BeDepot Cost - This is the amount that Be, Inc. will pay Developer for each
    copy of Product distributed.

                                       200
<PAGE>

                                    EXHIBIT B

                               Contact Information

Developer Company Name:                   Strata
                                          --------------------------------------

Developer Mailing Address:                567 South Valley View Drive
                                          Suite 202
                                          St. George, UT 84770
                                          --------------------------------------

Developer Company Phone:                  435-628-5218
                                          --------------------------------------

Developer Company Facsimile:              435-628-9756
                                          --------------------------------------

Marketing Contact Name:                   Dennis Derrick
                                          --------------------------------------

Marketing Contact Phone:                  435-628-5218 ext 5205
                                          --------------------------------------

Marketing Contact E-Mail:                 dennisd@strata3d.com
                                          --------------------------------------

Technical Contact Name:                   Gary Bringhurst
                                          --------------------------------------

Technical Contact Phone:                  435-628-5218 ext 5244
                                          --------------------------------------

Technical Contact E-Mail:                 garyb@strata3d.com
                                          --------------------------------------

Website URL:                              http://www.strata3d.com
                                          --------------------------------------

Customer Support E-mail (required):       support@strata3d.com
                                          --------------------------------------

435                                       435-628-9751
                                          --------------------------------------

Toll-Free Customer Support Phone:
                                          --------------------------------------

Customer Support Fax:                     435-628-9756
                                          --------------------------------------

                          BE, INC. CONTACT INFORMATION

                                Be, Incorporated
                          800 El Camino Real, Suite 400
                              Menlo Park, CA 94025
                               Ph: (650) 462-4100
                               Fax: (650) 462-4129

                          BeDepot Contact: Paula Draper
                               Ph: (650) 462-4184
                               Fax: (650) 462-4129
                              E-Mail: paula@be.com

                                       201

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00001-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00001-of-00352.parquet"}]]