Document:

Exhibit 10.11

 

 

     

     

    

 

“DEED
OF ASSIGNMENT PURSUANT TO A PRIVATE-PUBLIC PARTNERSHIP”

 

For the Construction of an Integrated Municipal
Solid Waste to Energy Complex in Moroni, Autonomous Island of Grande Comore, Union of the Comoros

 

 

GOUVERNORAT
DE L’ÎLE AUTONOME DE LA GRANDE COMORE (« Assignor »)

 

 

 

BIOCRUDE
TECHNOLOGIES, INC. (“Assignee”)

 

 

	AGREEMENT REFERENCE:	DEED-ASSIGNMENT/MSW-DAA/CA/2016/1
	 	 
	TRANSACTION CODE:	BCT/MCMUC/MORONI/UNION DES COMORES /1
	 	 
	CONTRACT GENERATION:	01

 

	Initials: __________	 	Initials: __________

 

    	2

     

    

 

Deed of Assignment pursuant to a Private-Public
Partnership

 

DEED
OF ASSIGNMENT PURSUANT TO PRIVATE-PUBLIC PARTNERSHIP

 

	AGREEMENT REFERENCE:	DEED-ASSIGNMENT/MSW-DAA/CA/2016/1
	 	 
	TRANSACTION CODE:	BCT/MCMUC/MORONI/UNION DES COMORES/1
	 	 
	DATE:	December __, 2016

 

This
Deed of Assignment (DA) pursuant to a Private-Public Partnership (PPP), as defined by the Governorate
of the Autonomous Island of Grande Comore, Union of the Comoros
and elaborated hereunder, sets forth the basic understandings between:

 

	FIRST PARTY	GOVERNORATE OF THE AUTONOMOUS ISLAND OF GRANDE COMORE, a Statutory Body constituted under Comorian Law, (hereinafter referred to as “Assignor”, which expression shall, unless repugnant to the context or meaning thereof, mean and include its successors and assigns) and having its office at Route de Moroni- Itsandra, Moroni, Autonomous Island of Grande Comore, Union of the Comoros, duly represented by the Governor, The Honourable HASSANI Hamadi, the Commissioner of the “Commissariat à l’Environnement, à l’Urbanisme, au Développement Durable et à l’Energie, à l’Emploi, à l’Entreprenariat et à la Solidarité”, Mr. Mohamed Abdou MLANAO, the Commissioner of the “Commissariat à la Sécurité intérieure, à la Fonction Publique, à l’Administration des Collectivités Territoriales Décentralisées, à la Réforme Administrative, chargé de l’Information”, Ms. Maissara Adam MONDOHA, and the Commissioner of the “Commissariat aux Finances, au Budget, à l’Economie, au Commerce Intérieur, à l’Industrie, au Plan, chargé de la promotion des Investissements”, Mr. Said Ahamada YOUSSOUF, by virtue of Resolution ad hoc;
	 	 
	AND	 
	 	 
	SECOND PARTY	BIOCRUDE TECHNOLOGIES, INC, a Corporation duly organized under the laws of Canada (hereinafter called “Assignee”) having its principle office at 1255 Phillips Square, Suite 605, Montreal, Quebec, Canada H3B 3G5, herein duly represented by the President and CEO, Mr. John MOUKAS, by virtue of corporate resolution ad hoc.
	 	 
	 	Hereinafter collectively called the “Parties”
	 	 
	PREAMBLE
	 	 
	WHEREAS	Assignee is an environmental services company specializing in the waste reformation milieu. Assignee has developed efficient, cost-effective, and environmentally friendly products, systems and processes for the reformation of waste material (MSW and Sewage Sludge, amongst other types of waste), waste management and the creation of renewable energy sources and resalable by-products (hereinafter the “Technology”);

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	3

     

    

 

Deed of Assignment pursuant to a Private-Public
Partnership

 

	WHEREAS	The Assignor has a residual materials (MSW and Sewage Sludge Waste) management plan and is desirous of having its MSW and sewage sludge managed, treated and procured with environmentally friendly technologies into renewable resources and not land filled, while achieving rigid standards for emissions, water contamination (leachate), human safety standards and environmental protection, while augmenting its waste processing management and disposal capabilities;
	 	 
	WHEREAS	Relating to Assignee’s proposal for the implementation of Integrated MSW-Energy Complexes for the Autonomous Island of Grande Comore, Union of the Comoros (Moroni) and the whole of the inter-related presented documents (Proposal, Power Point Presentations, Executive Summaries, concessions (MSW – Land - Supply of Water, Power Purchase Agreement “PPA”, etc.)), in which Assignee proposes the construction of Waste to Energy facilities for the management, treatment and transformation of waste in the Autonomous Island of Grande Comore, Union of the Comoros (called “the project” hereafter), according to the determination of Assignee;
	 	 
	WHEREAS	The Assignor has considered the advantages generated by the implementation of Integrated MSW – Energy Complex in Moroni, Autonomous Island of Grande Comore, Union of the Comoros, with respect to Environmental, Economic, Social and Technological well-being, as well as being in conformity to the standards of a “Clean Design Mechanism”, defined by the UNFCCC (Kyoto Accord); Refer to the “Implementation of an Integrated Municipal Waste to Energy Processing Complex” proposals for all of the above mentioned cities, to handle for MSW management and to the Concession Agreements for the MSW – Land - Supply of Water, Power Purchase Agreement “PPA”, etc.; whereby Assignor acknowledges receipt, has reviewed and is satisfied for full execution across the country of the Autonomous Island of Grande Comore, Union of the Comoros), and is desirous, by these presences in engaging with Assignee for the realization of same;
	 	 
	WHEREAS	The Assignor is conscientious and eager to coordinate its efforts to create a positive synergy with Assignee for the successful realization of said Integrated MSW-Energy Complex in the Autonomous Island of Grande Comore, Union of the Comoros for the remedy of the Autonomous Island of Grande Comore, Union of the Comoros’s Waste Management Dilemmas, and as such, the Governmental Authorities of the Autonomous Island of Grande Comore, Union of the Comoros will grant Assignee, by virtue of these presences, by Governmental Decree, full exclusivity for Municipal Solid Waste Management for the cities across the Autonomous Island of Grande Comore, Union of the Comoros, representing a minimum of 700 TPD of Municipal Solid Waste (MSW);
	 	 
	WHEREAS	On January 11, 2016, The Assignor has engaged in a transaction (the “Transaction”), by virtue of a “Private-Public Partnership” (PPP) with Assignee, defined within the context of this said “Deed of Assignment” (DA), whose purpose is for the utilization of Assignee’s proprietary technology, knowhow and financial resources for the realization of the exclusive business developments, the projects, under BOOT (Build, Own, Operate & Transfer) basis, across the Autonomous Island of Grande Comore, Union of the Comoros;

 

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	4

     

    

 

Deed of Assignment pursuant to a Private-Public
Partnership

 

	WHEREAS	The parties, following discussions, desire to enforce amendments discussed and reflected within these presences and agree to sign the Concession Agreements, the Power Purchase Agreement (PPA) and this Deed of Assignment as amended hereunder. Following the signature of these presences, the amended Concession Agreements, the Power Purchase Agreement (PPA) and this Deed of Assignment will replace the Concession Agreements, the Power Purchase Agreement (PPA) and this Deed of Assignment signed on the 11th of January 2016 and will become lawful and binding on the parties, present and future;
	 	 
	WHEREAS	This Deed of Assignment will define the framework of collaboration amongst the parties to clearly express their will to begin respectively on their level and for this, will carry out the terms of same in a spirit of mutual respect of the commitments entered into, frank collaboration, transparency and common support. Where necessary, other complementary agreements will be concluded and the range of the facilities which the parties intend to bring in order to achieve the goals contained therein.
	 	 
	WHEREAS	this preamble forms an integral part of these presences.

 

THE PARTIES AGREE TO SIGN THIS DEED OF ASSIGNMENT PURSUANT
TO A PRIVATE PUBLIC PARTNERSHIP OF THESE PARTIES, WHICH IS COMPRISED OF THE FOLLOWING THREE (3) PARTS (SECTIONS):

 

		I.	Deed of Assignment

 

		II.	Project Specifications

 

		III.	Annexures

 

NOW, THEREFORE, in consideration
of the mutual covenants, stipulations and agreements hereinafter contained the parties hereto, intending to be legally bound
in a formal agreement, do mutually covenant and agree as follows:

 

I.
DEED OF ASSIGNMENT

 

Chapter I: General Dispositions

 

This Deed of Assignment defines the contractual rights and obligations
of the Assignor and Assignee.

 

Article 1: Object

 

This Deed of Assignment embodies the engagement
of the Assignor to authorize the Assignee to Conceive, Design, Finance, Construct, Maintain and Exploit Municipal Solid Waste to
Energy Complexes in the municipalities within the Autonomous Island of Grande Comore, Union of the Comoros, to procure renewable
energy and marketable by-products (organic fertilizer).

 

Article 2: Duration of Deed of Assignment

 

This Deed of Assignment is for a duration/period
of thirty (30) years from the date of its application. It enters into force upon signature by all parties.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	5

     

    

 

Deed of Assignment pursuant to a Private-Public
Partnership

 

Article 3: Extension of Period Option
of Deed of Assignment

 

The Assignee has the option to renew this
contract for one additional period of thirty (30) years. The Assignee can execute the renewal option by (i) sending a written renewal
notice within twelve (12) months from the end of the initial contract stating the Assignee’s wishes to exercise its the contract
option to renew for an additional thirty (30) years; and (ii) if the Assignee has not breached its contractual obligations during
the first thirty (30) year contract period.

 

The tariff rates for the
waste management services offered to Assignor for the renewal period of the optional thirty (30) year term will be indexed at
a rate of 4.5% annually. The reference year for the application of the indexation of 4.5% will be the last year of the
original contract, using that years’ rate as the base for indexation for the following year, same being the first year
of the thirty (30) year renewal option.

 

Chapter II: Respective Obligations
of Parties

 

Article 4: Objective of Assignee’s’ Obligations

 

The Assignee shall:

 

		Ø	Conceive, Design, Finance, Construct,
Maintain and Exploit, Exclusively, a Municipal Solid Waste to Energy Complex in Moroni, in the Autonomous Island of Grande Comore,
Union of the Comoros, in compliance with national and international laws regarding the protection and preservation of the environment,
inter alia, the prevention and management of environmental pollution;

 

		Ø	Obtain and maintain, throughout the life
of the project, all necessary approvals required to certify best industry practices in the environmental protection milieu.

 

The Assignee Guarantees:

 

		Ø	To be in compliance with technical requirements
in force within the industry milieu and to use good construction practices and technologies, materials and equipment, of recognized
standards and quality;

 

		Ø	To effect an intellectual property and
skills transfer;

 

		Ø	To conduct social work for women and
                                                                                                                  children (through a foundation, that will be established by the Assignee). Funding will be from the sale of the Assignees
                                                                                                                  earned carbon credits, whereby Assignee will donate 10% of the Carbon Credits (CER’s) to same, annually, via a Revenue
                                                                                                                  Sharing Agreement. The project meets the criteria for a “Clean Design Mechanism” (CDM), pursuant to
                                                                                                                  article 12 of the UNFCCC (“Kyoto Accord”).

 

Article 5: Assignee’s Investment Plan and Financing
Terms

 

Assignee is responsible for the realization of the exclusive
business developments of the project(s) via BOOT (Build, Own, Operate & Transfer) basis, in Moroni, Autonomous Island
of Grande Comore, Union of the Comoros; as per the expectations of all parties, and stipulated in the provisions of the Concession
Agreements, to service the minimum amount of 700 TPD of MSW.

 

The Assignee also agrees that all costs in relation to the connecting,
synchronizing, turning on or testing, and maintenance of the equipment are the sole responsibility of Assignee, excluding payments
of processing and monitoring of the project as per government regulations and the provisions stipulated in the Concession Agreements,
which are the responsibilities of the other contracting parties in the Concession Agreements (Agents/Agencies of Assignor), endorsed
with Sovereign guarantees of the Assignor for execution of same.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	6

     

    

 

Deed of Assignment pursuant to a Private-Public
Partnership

 

Article 6: Assignee’s Depreciation
Policy

 

Amortization of plant and equipment will
be in accordance with the laws applicable to the Comorian company "Company to be created by Assignee" To
this end, the most durable equipment will be amortized using a straight-line depreciation method, over a period of 15 years,
to allow a minimum of one renewal before the expiry of the Concession Agreements.

 

Article 7: Repair and Maintenance of
the Project

 

The repair and maintenance of the project
is the sole responsibility of Assignee.

 

Assignee shall undertake a proper and prudent
repair and maintenance schedule, to ensure optimal functioning of the project (s) to provide services
in accordance with the provisions of this Deed of Assignment and the Concession Agreements (MSW, Land, Supply of Treated Effluent
and Power Purchase Agreement) associated with it.

 

Article 8: Accounting Provisions

 

The Assignee shall keep accounting records
of its project (s) activities in accordance with accounting rules and procedures of International Accounting Standards ("GAAP";
"Generally Accepted Accounting Principles" or "IFRS", "International Financial Reporting Standards").

 

Article 9: Concession Agreements Tariff
Rates

 

The tariff rates for the resale of electricity
to the national power corporation (Le Gestion de l’Eau et de l’Électricité aux Comores (MA-MWE)) are
set out in the Power Purchase Agreement (PPA), attached as annex 1.

 

The tariff rates for the tipping fees for
the supply of Municipal Solid Waste from the municipalities, the land lease rate and the rates for the treated effluent for the
project (s) are set out in the Municipal Solid Waste Concession Agreement, Land Lease Agreement & Supply of Treated Sewage/Effluent
Agreement, attached as annex 2.

 

The rates regarding the sale of fertiliser
will be subject to market rates.

 

Article 10: Assignee’s obligations,
vis-a-vis, Third Party Transactions

 

The Assignee will have organic fertilizer
as a derivative by-product of the project (s), for sale to third parties. It ensures that such sale will be in the state of the
art practices.

 

Article 11: Transfer, Sell or Surrender
of the Project (s)

 

The Assignee has the right to sell, transfer
or surrender the project (s) to a third party or lenders by notifying the Assignor in advance, in writing, of same.

 

Article 12: Conditions of Making Available
to the Public

 

The Assignor against remuneration will
make available Integrated MSW-Energy complexes for the management and processing of Municipal Solid Waste into renewable energy
and marketable by-products. In addition, it will sell marketable derivative by-products derived from the processing of the municipal
solid waste.

 

Electricity is made available to the public
pursuant to a Power Purchase Agreement (PPA) attached as annex 1.

 

Municipal Solid Waste treatment is performed
under the conditions defined in Section II of these presences, “Project Proposals and Specifications”
and is further elaborated in the Municipal Solid Waste Concession Agreement, Land Lease Agreement & Supply of Treated
Sewage/Effluent Agreement.

 

The Assignee will have organic fertilizer
as a derivative by-product of the project (s), for sale to third parties. It ensures that such sale will be in the state of the
art practices, in accordance with the regulations in force in the Autonomous Island of Grande Comore, Union of the Comoros.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	7

     

    

 

Deed of Assignment pursuant to a Private-Public
Partnership

 

Article 13: Terms of Remuneration of
Assignee

 

The Assignee will receive remuneration
for the project (s) as follows:

 

		Ø	Tipping fees paid by the municipalities
pursuant to the Concession Agreements, and endorsed by Assignor with Sovereign Guarantees;

 

		Ø	The sale of electricity to the National
Power Corporation (Le Gestion de l’Eau et de l’Électricité aux Comores (MA-MWE)) under the provisions
of the Power Purchase Agreement (PPA); and endorsed by Assignor with Sovereign Guarantees; and

 

		Ø	The sale of marketable derivative by-products
(fertilizer), which will be sold by Assignee in the market place. 

 

Article 14: Assignor’s Obligations

 

The Assignor shall:

 

		Ø	Ensure that the electrical network is
able to receive and transmit electricity, no later than one month before the anticipated date of commissioning and that no technical
or legal constraints inhibit the execution of these presences and the Concession and Power Purchase Agreements;

 

		Ø	Ensure and facilitate the requirements
for construction of the project (s) and the smooth transition to the operational phase (period), as of the anticipated date of
commissioning;

 

		Ø	Ensure, facilitate and deliver promptly
all necessary authorizations, permits and clearances, in accordance with applicable laws and inform the Assignee with diligence
and accuracy, if it so requests, in writing, what is requisite for same;

 

		Ø	Provide Assignee with all updated laws
and regulations applicable to areas of environment, sanitation and energy;

 

		Ø	Sign and execute the Concession Agreements,
Power Purchase Agreement(s) and consummate all of their obligations under same, required for the launching of the project(s), in
accordance to these presences, within sixty (60) days of Assignee’s written request for each facility in a city, representing
a minimum quantum of one (1) facility (ies) with a minimum processing capacity of 600 TPD per facility; failing to do so shall
constitute breach of said presences and Assignor will compensate Assignee for said breach, opportunity revenues lost due to delay/offset

 

		Ø	Guarantee and assure the execution of
all of their obligations inherent within the realms of the Concession Agreements and Power Purchase agreement (s) (land acquisition,
contractual conditions, exclusivity, administrative and fiscal facilities, authorizations, approvals, permits, etc...) for the
realization of the project(s).

 

Article 15: Assignee’s Obligations

 

The Assignee shall:

 

		Ø	Construct and commission each project
within 24 months of obtaining all necessary permits, approvals and clearances, related thereto;

 

		Ø	Create
a Comorian Corporation with a “Special Purpose Vehicle” (SPV) classification, for the Waste Management
related project in the Autonomous Island of Grande Comore, Union of the Comoros, with all the tax benefits set out in the Comorian
legal standards. The Comorian government is committed to issue the certificate of eligibility and subsequently award the license
giving the company the classification of Special Purpose Vehicle for claims of achieving the purpose of the Deed of Assignment;

 

		Ø	Engage to work primarily with Comorian
persons and legal entities, subject to competence and quality, as will be required for the interests, safeguard and profitability
of the project(s);

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	8

     

    

 

Deed of Assignment pursuant to a Private-Public
Partnership

 

		Ø	Provide adequate organization and qualified
personnel for the execution of operations;

 

		Ø	Comply at all times with the environmental
laws;

 

		Ø	Comply with its contractual obligations
of these presences and with those of the Concession Agreements and Power Purchase Agreement (s) and treat minimum quantities of
waste contained in the Concession Agreements; and

 

		Ø	Establish in the Autonomous Island of
Grande Comore, Union of the Comoros, a fully equipped laboratory to monitor and analyze the quality of water, air, soil and the
project's impact on these elements and personnel.

 

The Assignee shall ensure that the Project
(s) is (are) designed, built and completed in a good workmanlike manner using sound engineering construction
practices and using only materials and equipment that are new and of international utility grade quality such that, the useful
life of the Project (s) will be at least till the expiry date of the Concession Agreements and Power Purchase Agreement (s).

 

The Assignee shall ensure that design,
construction and testing of all equipment, facilities, components and systems of the Project shall be in accordance with the Comorian
Standards and Codes issued by the Bureau of Comorian Standards and/or internationally recognized Standards and Codes, such as:

 

	i.	 	American National Standards Institute (ANS)
	ii.	 	American Society of Testing and Materials (ASTM)
	iii.	 	American Society of Mechanical Engineers (ASME)
	iv.	 	American Petroleum Institute (API)
	v.	 	Standards of the Hydraulic Institute, USA
	vi.	 	International Organization for Standardization (ISO)
	vii.	 	Japanese Industrial Standards (JIS)
	viii.	 	Tubular Exchanger Manufacturer's Association (TEMA)
	ix.	 	American Welding Society (AWS)
	x.	 	National Electrical Manufacturers Association (NEMA)
	xi.	 	National Fire Protection Association (NFPA)
	xii.	 	International Electro-Technical Commission (IEC)
	xiii.	 	Expansion Joint Manufacturers Association (EJMA)
	xiv.	 	Heat Exchange Institute (HEI)
	xv.	 	American Water Works Association (AWWA)

 

Other international standards, established
to be equivalent or superior to the above standards shall also be acceptable. However, in the event of any conflict between the
requirements of the international codes and standards and the requirements of the country’s standards and regulations, the
latter shall prevail.

 

The Assignee is committed, if required
by Comorian law, to create a corporation (under the umbrella of the SPV, governing the resale of electricity to the National Power
Corporation (Le Gestion de l’Eau et de l’Électricité aux Comores (MA-MWE)).

 

The Assignee shall:

 

		Ø	Comply with laws and regulations applicable
to it, especially with regard to roads, police, health, labor and safety regulations;

 

		Ø	Maintain a prudent corporate governance
in regards to the administration of the use of its assets and the running of the project as an on-going concern (Business);

 

		Ø	respect and ensure respect for its employees,
contractors and suppliers and all rules relating to the hazard prevention, hygiene and safety; and

 

		Ø	Not use any materials that could endanger
human safety.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	9

     

    

 

Deed of Assignment pursuant to a Private-Public
Partnership

 

The Assignee agrees to sell exclusively
to the Assignor any net energy produced by the project(s) and the Assignor agrees to purchase all net energy produced by the project(s)
as per the provisions of the Power Purchase Agreement(s).

 

Article 16: Sharing of Risks

 

The risks associated with the performance
and operations of the project(s) are the sole responsibility of the Assignee.

 

Article 17: Assignor’s Monitoring
Mechanisms

 

The parties agree to the establishment
of an overseeing committee for the evaluation of the project(s). This committee will meet at least once every six months to assess,
evaluate and make recommendations of the project(s) and its (their) operation(s).

 

The Assignee shall provide on a website,
all pertinent details of influxes of materials and out-fluxes of by-products (solid, liquid, gas, etc...) from the project
(s); this information shall be updated on a bimonthly basis.

 

The parties agree that the Assignor can
perform spot checks whenever he decides as long as it complies with the provisions and procedures provided in the Concession Agreements
and Power Purchase Agreement (s).

 

Article 18: Sanctions and penalties

 

All sanctions and penalties shall conform
to the provisions stipulated in the Concession Agreements and the Power Purchase Agreement(s); refer to annex 1 & 2.

 

The obligations of the Assignee under these
presences shall be suspended in whole or part by force majeure, which include war, public disturbances, natural disasters and/or
other emergencies and will continue for a term for at least the duration of the event constituting of force majeure.

 

Article 19: Modifications

 

This Deed of Assignment may only be amended
by mutual consent of the parties, respecting the essence of same, that is to say, with an emphasis on efficiency, clarity and simplicity.

 

Any executed changes, once signed, will
be immediately applicable and will be annexed to this Deed of Assignment.

 

Article 20: Assignment of Contract

 

In case of an Assignment/Transfer of these
presences or of any Concession/Power Purchase Agreement(s) of the assignee to a new Entity, notwithstanding any termination, the
new Entity shall assume the all of the obligations, duties and liabilities of the present Assignee, and any unexpired obligation(s)
and/or ongoing project(s) started under these presences and not completed, will be obligated for completion.

 

Article 21: End of Contract

 

Under these presences, the parties agree
to a renewal or not. Upon renewing theses presences and contract(s) derived therefrom, both parties will adhere to the provisions
of same and article 28, hereunder.

 

Article 22: Amicable Dispute Resolution

 

The parties agree to settle amicably any
dispute that will arise from the interpretation or enforcement of this Deed of Assignment. Otherwise, the dispute shall be submitted
to competent courts in Canada (Ontario).

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	10

     

    

 

Deed of Assignment pursuant to a Private-Public
Partnership

 

Article 23: Arbitration

 

The arbitral forum chosen for this Deed of Assignment is that
of Ontario, Canada. Any dispute arising from the application of these presences shall be settled under the Rules of Arbitration
of the International Chamber of Commerce. Costs related to arbitration shall be shared equally between the parties. However, each
party will bear the cost of its own arbitrator(s). The parties may, however, with the court’s ruling, ask to be reimbursed
for their costs of arbitration.

 

Applicable Law

 

Only the courts of Canada shall have jurisdiction to hear disputes
that may arise, based on this Deed of Assignment. But before going to court, the parties have recourse to arbitration.

 

The parties agree to place all the provisions of this Agreement
under the jurisdiction of Canadian law.

 

Dispute Resolution

 

For all disputes that arise, the Disputes
will be resolved by arbitration, and will respect the rules, regulations and procedures

thereto. The Disputes shall be resolved by arbitration under
the Rules of Arbitration of the International Chamber of

Commerce. Herein under is the procedure to be followed:

 

	i.		The Arbitration tribunal shall consist of three (3) arbitrators to be appointed in accordance with
the rules of Arbitration of the International Chamber of Commerce. Each of the parties will select an arbitrator and the two (2)
arbitrators will select the third (3rd) arbitrator.

 

	ii.		The place of arbitration shall be France. The language of the arbitration shall be English.

 

	iii.		The arbitration tribunal's award shall be substantiated in writing. The arbitration tribunal shall
also decide on the costs of the arbitration proceedings and the allocation thereof.

 

	iv.		The award shall be enforceable in any court having jurisdiction in the country of the Assignor,
subject to the applicable Laws.

 

Article 24: Origin and Source of Project
Works (Procurement of Equipment, Civil Works, etc...)

 

The Assignee and its subcontractors, if
any, will endeavor to use as much as feasibly possible of services, materials and local raw materials and products manufactured
in the Autonomous Island of Grande Comore, Union of the Comoros, to the extent that these services, materials, raw materials and
products are available at competitive terms of price, quality, warranty and delivery time.

 

Article 25: Financial Provisions

 

Contracts signed under the provisions
of this said Deed of Assignment, shall be subject to specific financial and tax implications related to corporations exploiting
such projects, as provided by law, with the classification "Special Purpose Vehicle” (SPV), up to and including
all the tax benefits set out in the Comorian legal standards.

 

Transactions made under the provisions
of this said Deed of Assignment or contract(s) resulting therefrom, will be accounted for via a trading scheme in force in the
Autonomous Island of Grande Comore, Union of the Comoros, as they are executed and recorded.

 

Subject to the provisions of this Deed
of Assignment, the State of the Autonomous Island of Grande Comore, Union of the Comoros guarantees, for the duration of these
presences and for all Contract(s) arising therefrom, the Assignee the following:

 

		•	Possession of one or more bank accounts in the Autonomous Island of Grande Comore, Union of the
Comoros;

		•	Opening a foreign currency account in the Autonomous Island of Grande Comore, Union of the Comoros;

		•	The conversion and transfer of all monies (from the on-going concerns of the project(s)) to any
part of the world.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	11

     

    

 

Deed of Assignment pursuant to a Private-Public
Partnership

 

The Assignor also warrants that all
Expatriate staff of Assignee shall have the benefit of free conversion and free transfer to any part of the world, of all
monies derived from earnings or from the sale of personal effects.

 

Article 26: Tax Provisions

 

The Assignee will be exempt from the impositions
of Value Added Tax (VAT) and Corporate Income Taxes for the duration of the contract and the option of renewal thereof.

 

During the term of the Agreement and renewal
option, the Assignee will be exempt of any and all import / customs duties, levies and taxes implicated with the importation of
all machinery, vehicles, materials, equipment and other consumer goods requisite and contributing to the project, vis a vis, construction
of the infrastructure and development of the business (as defined within the context of this agreement),
and the daily operation of same.

 

The Assignee can expediently import/export
any goods for the benefit of/derived from the business, for the benefit of same.

 

The Assignee shall benefit from the procedure
of direct and immediate removal of all goods imported or it will cause to be imported for the purposes of the project(s), or the
transfer of any funds derived from the on-going concerns of the project(s) to any part of the world, designated by Assignee.

 

Article 27: Termination of Contract

 

Upon the occurrence of any default of either
party, the affected party will send a formal notice “Mise en Demeure” stating in detail the circumstances that
prompted the issuance of such notice. After the issuance of said notice, a consultation period of ninety (90) days or longer, if
agreed between the parties, will be realized. During this consultation period, the parties shall continue to perform their respective
obligations under this agreement. This Deed of Assignment may be amended by mutual consent of the parties under the same conditions
as those forms of signature, that is to say with an emphasis on efficiency, clarity and simplicity, if so required by both parties
for remedy of same.

 

At the end of the period of 90 days, unless
the parties have agreed otherwise or if the event of default has been corrected, the aggrieved party may require to exercise its
full rights of compensation/replacement, as the case may be for each party, of the defaulting party in accordance with the provisions
of the Concession Agreements and/or Power Purchase Agreement(s), if it will proceed with the termination of same.

 

Article 28: Renewal of Contract (Deed
of Assignment)

 

As an exception, any party may make known
its willingness to extend the contract for one additional period of thirty (30) years. The contract extension will be (i) if the
Party seeking to extend the initial period sends a written request to that effect to the other party and that party accepts it
within twelve (12) months before the end of the initial period, subject that the party asking the request for a renewal has not
been in default of any of its obligations inherent within the realms of these presences or any of the contracts arising therefrom.
If the accepting party does not reply within the aforesaid time frame, the renewal will be accepted as a “Tacit Renewal”,
respecting the provisions and stipulations of same and the Contracts derived there from.

 

Article 29: Confidentiality

 

For purposes of this agreement:

 

"Confidential Information",
in relation to and including the Disclosing Party, means any and all information, whether or not explicitly designated as
such, whether patentable or not, whether in written, oral or electronic form, disclosed by or on behalf of Disclosing party to
Recipient and pertaining to Disclosing party’s business, creation, products or technology, techniques, including, without
limitation, non-public information, know-how, whether technical or non-technical, trade secrets, data materials, inventions, designs,
formulas, ideas, developmental or experimental work, source codes, algorithms, records, studies, reports, business and marketing
plans and projections/costs, details of agreements and arrangements with third parties, other original works of authorship, customer
lists, contact lists, marketing strategies, terms of contracts, business plans, financial information or other subject matter pertaining
to any business of Disclosing party or any of its Affiliates, clients, consultants, suppliers, licensors or licensees and any other
trade secret and information which Disclosing party treats as confidential, including any information
entrusted to Disclosing party by third parties, including, without limitation, all information, clearly marked as Confidential
Information, held by that party or any agent or employee of that party, relating to the business, operations or undertaking of
that party.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	12

     

    

 

Deed of Assignment pursuant to a Private-Public
Partnership

 

The term Confidential Information shall
not include, however, information that (i) is or becomes generally available to the public, (ii) was lawfully available to the
Recipient on a non-confidential basis prior to its disclosure by the Disclosing Party or its Representatives (iii) becomes available
to the Recipient on a non-confidential basis from a Person who was not otherwise known by the Recipient or its Representatives
to be bound by a confidentiality or similar agreement with the Disclosing Party or any of its Representatives, or otherwise subject
to an obligation of confidentiality or secrecy to the Disclosing Party or its Representatives and that the information was not
transmitted to the Person by the Recipient, or (iv) is independently developed by the Recipient or its Representatives without
the use of the Confidential Information of the Disclosing Party. Confidential Information is not
or does not come within the public domain merely because features of the Confidential Information may be found separately or within
a general disclosure in the public domain.

 

“Confidentiality
Obligations”: Except as otherwise permitted in this Agreement or as authorized in writing by the Disclosing
Party, the Recipient shall (i) hold in confidence and not reproduce, distribute or disclose to any third-party other than its
Representatives any Confidential Information; (ii) protect such Confidential Information with at least the same degree of
care that Recipient uses to protect its own Confidential Information, but in no case, less than a reasonable degree of care;
(iii) use the Disclosing Party’s Confidential Information for no purpose other than pursuing the “Specified
Purpose”; (iv) limit access to the Disclosing Party’s Confidential Information to its Representatives having
a need to know such Confidential Information, who are informed of its confidential nature, and are bound by confidentiality
obligations; and (v) promptly notify the Disclosing Party upon discovery of any loss or unauthorized disclosure of the
Disclosing Party’s Confidential Information.

 

"Specified Purpose" means the sole purpose for which Confidential Information is to be disclosed by a party to the other party, which is
to enable the parties to co-operate in a possible business transaction (engagement) between Receiving Party, its subsidiaries or
clients, and Disclosing Party with respect to Disclosing Party's information, technologies, commercial practices and know-how.

 

Certain documents and information, public
or private, for the fulfillment of the contract, must be confidential. Accordingly, each Party undertakes to respect the confidentiality
not to harm the other party and refrain from disclosing any documents, information, ideas, practices, know-how, data or design
as may be aware in the course of this agreement. Both parties agree that they must not, without the prior written approval of the
Disclosing Party, use, disclose, divulge or deal with any Confidential Information, nor cause, permit or allow any act, matter
or thing to be done, omitted or occur whereby any Confidential Information may become known or be used by, or be disclosed or communicated
to, any other person, except strictly in accordance to these provisions of “Specified Purpose”.

 

For the purposes of this clause, the Disclosing
Party and Recipient shall assume full responsibility for its Affiliates and/or Representatives, as if it were like itself.

 

“Disclosures Required by Law”: If the Recipient or any of its Representatives is requested or required in connection with any legal or governmental
proceeding to disclose or otherwise becomes legally compelled to disclose any Confidential Information, the Recipient shall provide
the Disclosing Party with prompt written notice, if permitted by law, so as to enable the Disclosing Party, sufficiently in advance
of the disclosure with reasonable opportunity to prevent the disclosure or to seek a protective order or other appropriate remedy
or waive compliance with this Agreement and provided further that in the event that such protective order or other remedy is not
obtained, Recipient shall (i) make any required disclosures in consultation with the Disclosing Party; (ii) furnish only that portion
of the Confidential Information which Recipient is advised by written opinion of counsel is legally required; and (iii) exercise
Recipient’s best efforts to obtain reliable assurance that confidential treatment shall be accorded such Confidential Information.

 

“Remedies”: The
Recipient acknowledges that its breach of this Agreement may cause irreparable damage to the Disclosing Party for
which monetary damages would not be a sufficient remedy by itself. The rights and remedies provided to each Party in this Agreement
are cumulative and in addition to any other rights and remedies available to such Party at law or in equity.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	13

     

    

 

Deed of Assignment pursuant to a Private-Public
Partnership

 

“No License Granted”: The Confidential Information is and shall remain the sole property of the Disclosing Party (or the third-party which has
disclosed the information to the Disclosing Party). The Recipient recognizes and agrees that nothing contained in this Agreement
shall be construed as granting any property rights, by license or otherwise, to any Disclosing Party’s Confidential Information.

 

“No Representations”: All Confidential Information is provided on an “as is” basis and the Recipient agrees and acknowledges
that neither the Disclosing Party nor any of its Representatives are making any representation or warranty, express or implied,
as to the accuracy or completeness of the Confidential Information, and neither the Disclosing Party nor any of its Representatives
will have any liability to the Recipient, its Representatives or any other Person relating to or resulting from the use of or reliance
on the Confidential Information or for any errors therein or omission therefrom.

 

Article 30: Insurance

 

The Assignee is required throughout the
term of these presences and contracts derived therefrom, to take out with one or more insurance company’s known to be solvent,
the insurance policies covering all of its responsibilities and all risks inherent within the realms of these presences and contracts
derived therefrom.

 

Upon disaster and damage of the project(s),
the insurance money paid will be used to repair the disaster, including the reconstruction of the Works or their rehabilitation
by rebuilding the destroyed items. In case of total loss, the amount of compensation will be given priority to creditors and the
balance to the Assignee.

 

Article 31: Special Provisions

 

This Deed of Assignment shall enter into
force, immediately after signature.

 

This Deed of Assignment is the legal equivalent
of a contract: Legal, Compellable, Coaching and Enforceable. It provides a benchmark for contracts and schedules thereunder. This
Deed of Assignment is the basis for the drafting of all contracts arising therefrom, being by nature an extrinsic contract agreement
and commitment. This Deed of Assignment once signed gives strength and validity to all other subsequent agreements.

 

It will be a fundamental contractual nature
between the parties insofar as it represents the main elements of the parties' intent. The Deed of Assignment concerns the projects
for the municipality of Moroni and other cities within the Moroni District, Autonomous Island of Grande Comore, Union of the Comoros.

 

Article 32: Notices

 

Unless otherwise stated, notices to be
given under this Agreement including but not limited to a notice of waiver of term, breach of any term of this Agreement and termination
of this Agreement, shall be in writing and shall be given by hand delivery/ recognized international courier, mail, telex, facsimile
or email and delivered or transmitted to the parties at their respective addresses set forth below:

 

Name, Address, Tel. &
Fax of Assignor:

 

Gouvernorat de l’Île
Autonome de la Grande Comore

Route de Moroni- Itsandra

Moroni, Île Autonome
de la Grande Comore, Union des Comores

 

(Attn: The Honourable HASSANI Hamadi, Governor and/or

Mr. Mohamed Abdou MLANAO, Commissaire
à l’Environnement, à l’Urbanisme, au Développement Durable et à
l’Énergie, à l’Emploi, à l’Entreprenariat et à la Solidarité)

 

Tel: +269 773 13 64; +269 773
84 77; +269 764 44 77

Facsimile:

Email: sgg.ngazidja@gmail.com

Website: http://www.gouvernorat-ngazidja.com

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	14

     

    

 

Deed of Assignment pursuant to a Private-Public
Partnership

 

Name, Address, Tel. & Fax of Assignee:

 

BioCrude Technologies, INC.

1255 Phillips Square, Suite 605

Montreal, Quebec, Canada H3B 3G5

 

(Attn: Mr. John MOUKAS, Chairman/CEO)

 

Tel: (877) 878-1268

Facsimile: (877) 778-1568

Email: jmoukas@biocrudetech.com

Website: http://www.biocrudetech.com

 

Nota Bene: All notices under this Agreement shall be
in English or French.

 

Article 33: Language

 

The
Parties have required that this Deed of Assignment, the Concession Agreements and Power Purchase Agreement(s),
attached as annexures, and all notices, deeds, documents, and other
instruments to be given pursuant hereto be drawn in the English
and French languages. Les parties ont exigé que cette entente ainsi que tous les avis et autres documents exécutés
en vertu des présentes soient rédigés en langue
anglaise et française.

 

Article 34: Publication/Advertise of excerpts of this Deed
of Assignment in the Official Gazette

 

An
excerpt of this Deed of Assignment pursuant to a Private-Public Partnership, including the name and quality of contracting
parties as well as the purpose, duration and essence of the contract,
will be published in the Official Gazette of the Autonomous
Island of Grande Comore, Union of the Comoros, by the Assignor.

 

Article 35: Project Specifications

 

The
specifications of the project, annexed hereto, consists of administrative and technical clauses defining the conditions, the
duties and obligations of parties and their participants for project
(s) realization, in regards to infrastructure, public utility works, operations
and management services. It forms an integral part of this agreement.

 

Article 36: Annexures

 

The following annexes are an integral part of this contract:

 

		1.	Power Purchase Agreement(s) (PPA);

		2.	Municipal Solid Waste Concession Agreement(s), Land Lease Agreement(s) and the Supply of Treated
Effluent Agreement(s);

		3.	Administrative authorizations.

 

Article 37: Registration

 

The Assignor is exempt from registration fees. All expenses
related to the registration formalities shall be borne by the Assignor.

 

IN WITNESS WHEREOF, the parties hereto have caused this
Deed of Assignment (DA) to be executed by their duly authorized representatives, as of the day and year set out below.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	15

     

    

 

 

 

    	16

     

    

 

 

 

    	17

     

    

 

Deed of Assignment pursuant to a Private-Public
Partnership

 

II.
Project Specifications

 

The specifications of the project, annexed
hereto, consists of administrative and technical clauses defining the conditions, the duties and obligations of parties and their
participants for project (s) realization, in regards to infrastructure, public utility works, operations and management services

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	18

     

    

 

Deed of Assignment pursuant to a Private-Public
Partnership

 

III.
Annexures

 

	1.	Power Purchase Agreement(s) (PPA);

	2.	Municipal Solid Waste Concession Agreement(s), Land Lease Agreement(s) and the Supply of Treated
Effluent Agreement(s);

	3.	Administrative authorizations.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	19

     

    

 

Deed of Assignment pursuant to a Private-Public
Partnership

 

Annex
1.

 

Power Purchase Agreement(s) (PPA)

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	20

     

    

 

Deed of Assignment pursuant to a Private-Public
Partnership

 

Annex
2.

 

Municipal Solid Waste Concession Agreement(s), Land Lease
Agreement(s) and the Supply of Treated Effluent Agreement(s)

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	21

     

    

 

Deed of Assignment pursuant to a Private-Public
Partnership

 

Annex
3.

 

Administrative
authorizations (if applicable) required 

 

The
table below gives the name and status of all the Statutory and Non-Statutory Clearances involved in
this project.

 

	Statutory Clearances
	Authorization of Pollution Control	Commissariat à l’Environnement, à l’Urbanisme, au Développement Durable et à l’Énergie, à l’Emploi, à l’Entreprenariat et à la Solidarité
	Pollution Clearance from the Ministère de la Production, de l'Environnement, de l'Énergie, de l'Industrie et de l'Artisanat de l’Union des Comores and Consent to Establish and Operate Plant	Commissariat à l’Environnement, à l’Urbanisme, au Développement Durable et à l’Énergie, à l’Emploi, à l’Entreprenariat et à la Solidarité
	Civil Aviation Clearance for Stack Height	Commissariat à l’Environnement, à l’Urbanisme, au Développement Durable et à l’Énergie, à l’Emploi, à l’Entreprenariat et à la Solidarité
	Municipal board for treated sewage	Commissariat à l’Environnement, à l’Urbanisme, au Développement Durable et à l’Énergie, à l’Emploi, à l’Entreprenariat et à la Solidarité & le Gestion de l'Eau et de l'Électricité aux Comores (MA-MWE)
	Town & Country Planning Clearance	Commissariat à l’Environnement, à l’Urbanisme, au Développement Durable et à l’Énergie, à l’Emploi, à l’Entreprenariat et à la Solidarité
	Host Country Approval for CDM under Kyoto protocol	Commissariat à l’Environnement,
    à l’Urbanisme, au Développement Durable et à l’Énergie, à l’Emploi,
    à l’Entreprenariat et à la Solidarité
	Non-Statutory Clearances
	Construction power	le Gestion de l'Eau et de l'Électricité aux Comores (MA-MWE)
	Power Purchase Agreement (PPA)	Commissariat à l’Environnement, à l’Urbanisme, au Développement Durable et à l’Énergie, à l’Emploi, à l’Entreprenariat et à la Solidarité & le Gestion de l'Eau et de l'Électricité aux Comores (MA-MWE)
	Power evacuation arrangements	Commissariat à l’Environnement, à l’Urbanisme, au Développement Durable et à l’Énergie, à l’Emploi, à l’Entreprenariat et à la Solidarité & le Gestion de l'Eau et de l'Électricité aux Comores (MA-MWE)

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	22Exhibit 10.12

 

 

     

     

    

 

POWER PURCHASE
AGREEMENT (PPA)

 

For the Procurement of Power on Long Term Basis
from Power Station to be set up in the Municipality of Moroni, Autonomous Island of Grande Comore, Union of the Comoros and Operating
on MSW

 

 

 

LE GESTION
DE L’EAU ET DE L’ÉLECTRICITÉ AUX COMORES (MA-MWE)

 

 

 

BIOCRUDE TECHNOLOGIES,
INC.

 

 

 

	AGREEMENT REFERENCE:	BIOCRUDE/MCMUC/MSWC-LLC/CA/2016/1
	 	 
	TRANSACTION CODE:	BCT/MCMUC/MORONI/COMOROS/1
	 	 
	CONTRACT GENERATION:	01

 

	Initials: __________	Initials: __________

 

    	2

     

    

 

Power Purchase Agreement (PPA)

 

Table of
Contents

 

	1.	ARTICLE 1: DEFINITIONS AND INTERPRETATION 	6
	2.	ARTICLE 2: TERM OF AGREEMENT 	15
	3.	ARTICLE 3:  CONDITIONS SUBSEQUENT TO BE SATISFIED BY THE SELLER AND THE PROCURER	16
	4.	ARTICLE 4: DEVELOPMENT OF THE PROJECT	18
	5.	ARTICLE 5: CONSTRUCTION	21
	6.	ARTICLE 6: SYNCHRONISATION, COMMISSIONING AND COMMERCIAL OPERATION 	23
	7.	ARTICLE 7: OPERATION AND MAINTENANCE	24
	8.	ARTICLE 8: CAPACITY, AVAILABILITY AND DISPATCH	24
	9.	ARTICLE 9: METERING AND ENERGY ACCOUNTING 	26
	10.	ARTICLE 10: INSURANCES 	26
	11.	ARTICLE 11: BILLING AND PAYMENT 	27
	12.	ARTICLE 12: FORCE MAJEURE 	32
	13.	ARTICLE 13: EVENTS OF DEFAULT & TERMINATION 	35
	14.	ARTICLE 14: LIMITATION OF LIABILITY 	38
	15.	ARTICLE 15: ASSIGNMENTS AND CHARGES 	38
	16.	ARTICLE 16: GOVERNING LAW AND DISPUTE RESOLUTION (ARBITRATION) 	39
	17.	ARTICLE 17: MISCELLANEOUS PROVISIONS	40
	SCHEDULE I 	49
	SCHEDULE I.A: SITE 	50
	SCHEDULE II: INITIAL CONSENTS 	51
	SCHEDULE III: FUNCTIONAL SPECIFICATIONS 	52
	SCHEDULE IV: COMMISSIONING & TESTING 	53
	SCHEDULE V: TARIFF 	55
	SCHEDULE VI: DETAILS OF INTERCONNECTION POINT & FACILITIES	56
	SCHEDULE VII: REPRESENTATIONS & WARRANTIES 	57
	SCHEDULE VIII: QUOTED TARIFF 	58
	QUOTED TARIF FEE WITH ESCALATING INDEX 	58
	SCHEDULE IX: SUBSTITUTION RIGHTS OF THE LENDERS 	59

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	3

     

    

 

Power Purchase Agreement (PPA)

 

POWER PURCHASE
AGREEMENT (PPA)

 

THIS AGREEMENT is made and effective the __th
day of December, 2016.

 

	AGREEMENT REFERENCE:	 	BIOCRUDE-MCMUC/ MSWC-LLC/CA/2016/1
	 	 	 
	TRANSACTION CODE:	 	BCT/MCMUC/MORONI/COMOROS/1
	 	 	 
	CONTRACT GENERATION:	 	01
	 	 	 
	FIRST PARTY:	 	
        LE
GESTION DE L’EAU ET DE L’ÉLECTRICITÉ AUX COMORES (MA-MWE), a Statutory Body constituted under Comorian
Law, (which expression shall,
unless repugnant to the context or meaning thereof, mean and include its successors
and assigns) and having its proxy/satellite office at Route de Moroni-
Itsandra, Moroni, Autonomous Island of Grande Comore, Union of the Comoros,
acting through its General Management Division, duly represented by
the Commissaire à l’Environnement, à l’Urbanisme, au Développement
Durable et à l’Énergie, à l’Emploi,
à l’Entreprenariat et à la Solidarité, Mr. Mohamed
Abdou MLANAO, by virtue of resolution ad hoc; 

         

        Hereinafter called the “Procurer”;

	 	 	 
	SECOND PARTY:	 	
        BIOCRUDE
        TECHNOLOGIES, INC, a Corporation duly organized under the laws
        of Canada (hereinafter called “Seller”) having its principle office at 1255
        Phillips Square, Suite 605, Montreal, Quebec, Canada H3B 3G5, herein
        duly represented by the President
        and CEO, Mr. John MOUKAS, by virtue of corporate
        resolution ad hoc; 

         

        Hereinafter called the “Vendor”;

	 	 	 
	AND	 	 
	 	 	 
	INTERVENING PARTY:	 	Gouvernorat de l’Île
Autonome de la Grande Comore, a Statutory Body constituted
under Comorian Law, (hereinafter referred to as “MCMUC”, which expression
shall, unless repugnant to the context or meaning thereof, mean and include
its successors and assigns) and having its office at Route de Moroni-Itsandra, Moroni, Autonomous Island of Grande Comore, Union
of the Comoros, duly represented
by the Governor, The Honourable Mr. HASSANI Hamadi, by virtue
of resolution ad hoc;
	 	 	 
	 	 	Commissariat à l’Environnement, à l’Urbanisme, au Développement Durable et à l’Énergie, à l’Emploi, à l’Entreprenariat et à la Solidarité, a Statutory Body constituted under Comorian Law, (which expression shall, unless repugnant to the context or meaning thereof, mean and include its successors and assigns) and having its office at Route de Moroni- Itsandra, Moroni, Autonomous Island of Grande Comore, Union of the Comoros, duly represented by the Commissioner, Mr. Mohamed Abdou MLANAO, by virtue of resolution ad hoc;

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	4

     

    

 

Power Purchase Agreement (PPA)

 

	 	 	Commissariat à la Sécurité intérieure, à la Fonction Publique, à l’Administration des Collectivités Territoriales Décentralisées, à la Réforme Administrative, chargé de l’Information, a Statutory Body constituted under Comorian Law, (which expression shall, unless repugnant to the context or meaning thereof, mean and include its successors and assigns) and having its office at Route de Moroni- Itsandra, Moroni, Autonomous Island of Grande Comore, Union of the Comoros, duly represented by the Commissioner, Ms. Maissara Adam MONDOHA, by virtue of resolution ad hoc;
	 	 	 
	 	 	Commissariat aux Finances, au Budget, à l’Economie, au Commerce Intérieur, à l’Industrie, au Plan, chargé de la promotion des Investissments, a Statutory Body constituted under Comorian Law, (which expression shall, unless repugnant to the context or meaning thereof, mean and include its successors and assigns) and having its office at Route de Moroni- Itsandra, Moroni, Autonomous Island of Grande Comore, Union of the Comoros, duly represented by the Commissioner, Mr. Said Ahamada YOUSSOUF, by virtue of resolution ad hoc;
	 	 	 
	 	 	Hereinafter called the “Intervenant” and/or “Guarantor”.
	 	 	 
	WHEREAS	 	On  January  11,  2016,  The  Assignor  has  engaged  in  a  transaction  (the “Transaction”), by virtue of a “Private-Public Partnership” (PPP) with Assignee, defined within the context of this said “Power Purchase Agreement” (PPA);
	 	 	 
	WHEREAS	 	The parties, following discussions, desire to enforce amendments discussed and reflected within these presences and agree to sign this Power Purchase Agreement (PPA) as amended hereunder. Following the signature of these presences, the amended Power Purchase Agreement (PPA) will replace the Power Purchase Agreement (PPA) signed on the 11th of January 2016 and will become lawful and binding on the parties, present and future;
	 	 	 
	WHEREAS	 	“Procurer” and “Seller” are hereinafter referred to individually as the “Party” and collectively as the “Parties”;
	 	 	 
	WHEREAS	 	The Procurer has identified the Project
namely, 6.5 MW power plant based on municipal
solid waste at Moroni, Autonomous Island of Grande Comore, Union of the
Comoros details of which are as set out in the Schedule I.A.
	 	 	 
	WHEREAS	 	The Seller has completed the initial studies as contained in Project Report; to obtain Initial Consents required for the Project.
	 	 	 
	WHEREAS	 	The Seller will construct the Project for a minimum Capacity (as defined hereunder) of 3.8 MW (Net) and 5 MW (Gross) and sale and supply of a minimum of 100% of net available electricity in bulk there from to the Procurer in accordance with the terms of this Agreement.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	5

     

    

 

Power Purchase Agreement (PPA)

 

	WHEREAS	 	The Parties have agreed to sign this Power Purchase Agreement setting out the terms and conditions for the construction, operation and maintenance of the Project, and supply of electricity by the Seller to the Procurer.
	 	 	 
	WHEREAS	 	A General Continuing Guaranty will be granted and added to this contract in order to secure the regularity of Tariff payments during the term of this contract.

 

NOW THEREFORE, THIS AGREEMENT WITNESSETH AND IT IS HEREBY AGREED
BY AND BETWEEN THE PARTIES AS FOLLOWS:

 

		1.	ARTICLE
1: DEFINITIONS AND INTERPRETATION

 

		1.1	Definitions

 

This Agreement shall be co-terminus with the
Concession Agreement and is to be read, for any interpretation, together with the provisions of the Concession Agreement.

 

The capitalized terms that are used but not
defined in this Agreement shall have the same meaning as given to them in the Concession Agreement.

 

“Act” or “Electricity
Act”: means the Autonomous Island of Grande Comore, Union of the Comoros Electricity Act of 1998, or any amendments made
to the same or any succeeding enactment thereof;

 

“Agreed Form”: means,
in relation to any document, the form of the said document most recently agreed to by the Parties and initialed by them for identification;

 

“Agreement” or “Power
Purchase Agreement” or “PPA”: means this document including its recitals and Schedules;

 

“Appropriate Commission”:
means the Electricity Regulatory Commission constituted under the section of the Electricity Act and the Electricity Regulatory
Commissions Act and such other succeeding authority or commission as may be notified by Government from time to time;

 

“Authorized Representative “:
shall mean the body corporate authorized by the Procurer to carry out the said negotiations and sign on their behalf;

 

“Bill Dispute Notice”: means
the notice issued by a Party raising a Dispute regarding a Bill or a Supplementary Bill issued by the other Party;

 

“Business Day”: means with
respect to Seller and Procurer, a day other than Sunday or a statutory holiday, on which the banks remain open for business in
the State in which the Procurer's registered office is located;

 

“CERC”: means the Central Electricity Regulatory
Commission, as defined in the Electricity Act;

 

“Commercial Operation Date “
or “COD”: means, in relation to the Power Station, the date one day after the date when the Procurer receives
a Final Test Certificate of the Independent Engineer as per the provisions of clause 6.3.1; “Commissioning” or “Commissioned”
with its grammatical variations means, the Unit of the Power Station have passed the Commissioning Tests successfully;

 

“Commissioning Tests” or “Commissioning
Test”: means the Tests provided in Schedule IV herein;

 

“Commissioned Unit”: means the Unit in respect
of which COD has occurred;

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	6

     

    

 

Power Purchase Agreement (PPA)

 

“Concession Agreement”:
means the agreement(s) entered into between the Seller and the Municipal Corporation of MORONI for the transportation and supply
of Municipal Solid Waste (MSW) required for conversion into RDF for the operation of the Power Station.

 

“Construction Contractor/s”:
means one or more main contractors, appointed by the Seller to design, engineer, supply, construct and commission the Project;

 

“Construction Period”: means
the period from (and including) the date upon which the Construction Contractor is instructed or required to commence work under
the Construction Contract up to (but not including) the Commercial Operation Date of the Unit in relation to the Power Station;

 

“Consultation Period”: means the period, commencing
from the date of issue of a Seller Preliminary Default Notice or a Procurer Preliminary Default Notice as provided in Article 14
of this Agreement, for consultation between the Parties to mitigate the consequence of the relevant event having regard to all
the circumstances;

 

“Contract Year”: means the
period beginning on the Effective Date (as defined hereunder) and ending on the immediately succeeding March 31 and thereafter
each period of 12 months beginning on May 1 and ending on March 31 provided that:

 

	i.	 	in the financial year in which Scheduled COD of the Unit would have occurred, a Contract Year shall end on the date immediately before the Scheduled COD of the Unit and a new Contract Year shall begin once again from the Scheduled Commercial Operation Date of the Unit and end on immediately succeeding March 31 and provided further that 
	 	 	 
	ii.	 	the last Contract Year of this Agreement shall end on the last day of the term of this Agreement; 

 

Provided that for the purpose of payment, the tariff will be the
Quoted Tariff for the applicable Contract Year as per Schedule VII;

 

“Capacity”: means

 

	i.	 	rated net capacity expressed in MW of Power Station, at the Interconnection Point, as provided in the attached proposal documentation, 
	 	 	 
	ii.	 	in case the Seller exercises its option as per clause 3.1.1 (a), the rated net capacity expressed in MW of Power Station, up to the maximum of the Capacity demanded, or 

 

such rated capacities as may be determined in accordance with clause
6.3.4 or clause 8.2 of this Agreement.

 

“Concession” means collectively
all the rights granted by First Party to Corporation under this Agreement with respect to developing, implementing, constructing,
operating and maintaining the Plant for the management, processing and disposal of the Municipal Waste generated from within the
First Party Supply Area, subject to all the terms, conditions, covenants and obligations of this Agreement, and the Municipal Solid
Waste Concession Agreement, Land Lease Agreement & Supply of Treated Sewage/Effluent Agreement.

 

“Control Centre” or “Nodal
Agency”: means the RLDC or SLDC or such other load control centre designated by the Procurer from time to time
through which the Procurer shall issue Dispatch Instructions to the Seller for the Power Station;

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	7

     

    

 

Power Purchase Agreement (PPA)

 

“Debt Service”: means the
amounts which are due under the Financing Agreements by the Seller to the Lenders, expressed in United States Dollars;

 

“Declared Capacity”: In
relation to a Unit or the Power Station at any time means the net capacity of the Unit or the Power Station at the relevant
time (expressed in MW at the Interconnection Point) as declared by the Seller in accordance with the Grid Code and dispatching
procedures as per the Availability Based Tariff;

 

'Declared Price of Land”: means
the rental amount as mentioned in the Land Concession Agreement by the Authorized Representative, at which the identified
land for the Site will be made available to the Seller.

 

“Delivery Point” or “Interconnection
Point”: means the points of delivery specified in Schedule VI for fulfilling the obligation of the Seller to deliver
the Contracted Capacity to the Procurers;

 

“DRERC”: means the Electricity
Regulatory Commission, as defined in the Electricity Act, or its successors; 

 

“Direct Non-Natural Force Majeure
Event”: shall have the meaning ascribed in clause 12.3 (ii)(1);

 

“Dispute” means any dispute
or difference of any kind between a Procurer and the Seller, in connection with or arising out of this Agreement including any
issue on the interpretation and scope of the terms of this Agreement as provided in Article 17;

 

“Dispatch Instruction”:
means any instruction issued by the Procurer to and/or the Seller, in accordance with applicable Grid Code and this Agreement;

 

“Due Date”: means the seventh
(7th) day after a Weekly Bill or a Supplementary Bill is received and duly acknowledged
by any Procurer (or, if such day is not a Business Day, the immediately succeeding Business Day) by which date such bill is payable
by the said Procurer;

 

“Effective Date”: means
the date of the acquisition of the Land Concession Agreement and the MSW Concession Agreement, in accordance with the provisions
of the Share Purchase Agreement (as defined hereunder);

 

“Electricity Laws”: means
the Electricity Act, herein above defined and the rules and regulations made there under from time to time along with amendments
thereto and replacements thereof and any other Law pertaining to electricity including regulations framed by the Appropriate Commission,
as of these presences;

 

“Electrical Output”: means
the net electrical output of the Power Station at the Delivery Point, as expressed in kWh;

 

“Emergency”: means a condition
or situation that, in the opinion of the Procurer or RLDC or SLDC or the agency responsible for operating and maintaining the Interconnection
and Transmission Facilities or the transmission company, as the case may be, poses a significant threat to the Procurer's or the
said agency's or transmission company's ability to maintain safe, adequate and continuous electricity supply to its customers,
or seriously endangers the security of persons, plant or equipment;

 

“Energy Charges”: Shall
have the meaning ascribed to this term under Schedule V;

 

“Expiry Date”: means the
30th anniversary of the Commercial Operation Date of the Power Station, of the
term. If the renewal option of thirty (30) years is exercised, then the expiry date shall be after the 30th
anniversary year of the renewal term.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	8

     

    

 

Power Purchase Agreement (PPA)

 

“Final Test Certificate”: means

 

	i.	 	a certificate of the Independent Engineer certifying and accepting the results of a Commissioning Test/s in accordance with clause 6.3 of this Agreement; or
	 	 	 
	ii.	 	a certificate of the Independent Engineer certifying the result of a Repeat Performance Tests in accordance with clause 8.1 of this Agreement; 

 

“Financial Closure” or “Financial
Close”: Means the execution of all the Financing Agreements required for the Project and fulfillment of conditions precedents
and waiver, if any, of any of the conditions precedent for the initial draw down of funds there under;

 

“Financing Agreements”:
means all the loan agreements, notes, indentures, security agreements, letters of credit and other documents relating to the financing
of the Project on or before the COD of the Power Station, as may be amended, modified, refinanced or replaced from time to time,
but without in anyway increasing the liabilities of the Procurers therein;

 

“Force Majeure”: shall the meaning ascribed thereto
in clause 12.3;

 

“Forced Outrage”: shall have the meaning ascribed
thereto in the Grid Code;

 

“Fuel”: means primary fuel
used to generate electricity namely, Refuse Derived Fuel (RDF) & Biogas (Biomethanation);

 

“Fuel Supply Agreements”:
means the Concession Agreement entered into between the Seller and the Municipal Corporation and intervening governmental authorities,
for the transportation of the Municipal Solid Waste (MSW) to the Complex;

 

“Functional Specifications “:
means the technical requirements and parameters described in Schedule III of this Agreement and as provided in Grid Code relating
to the operation, maintenance and dispatch of any Unit and the Power Station;

 

“Grid Code “ or “IEGC”:
means any set of regulations or codes issued by Appropriate Commission as amended and revised from time to time and legally binding
on the Sellers and Procurers governing the operation of the Grid System or any succeeding set of regulations or code;

 

“Grid System”: means the
Interconnection and Transmission Facilities and any other transmission or distribution facilities through which the Procurer supply
electricity to their customers or the transmission company transmits electricity to the Procurer;

 

“Independent Engineer”:
means an independent consulting engineering firm or group appointed jointly by the Procurer and the Seller to carry out the functions
in accordance with clause 4.7.1 and Article 6, Article 12 and Article 8 herein.

 

	i.	 	a certificate of the Independent Engineer certifying and accepting the results of a Commissioning Test/s in accordance with clause 6.3.1 of this Agreement; or
	 	 	 
	ii.	 	provided that separate Independent Engineer may be appointed for the purposes of clause 4.7.1, Article 6, Article 12 and Article 8; 
	 	 	 
	iii.	 	provided further that the separate Independent Engineer may be appointed for each financial year for the purposes of Article 8, and in such case, such Independent engineer shall be appointed at least ninety (90) days prior to the beginning of the financial year. 

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	9

     

    

 

Power Purchase Agreement (PPA)

 

“Indirect Non-Natural Force Majeure Event”:
Shall have the meaning ascribed thereto in clause 2.3(ii)(2).

 

“Initial Consents”: shall mean the consents listed
in Schedule II.

 

“Initial Performance Retest Period”: shall have
the meaning ascribed thereto in clause 6.3.3 of this Agreement.

 

“Interconnection Facilities”
or “Interconnection and Transmission Facilities”: means the facilities on the Procurer side of the Interconnection
Point for receiving and metering Electrical Output in and accordance with this Agreement and which shall include, without limitation,
all other transmission lines and associated equipment, transformers and associated equipment, relay and switching equipment and
protective devices, safety equipment and, subject to clause 5.3 and Schedule VI, the Metering System required for the Project.
The Interconnection Facilities also include the facilities for receiving power at the Delivery Point where the transmission line
from the Power Station Switchyard end is injecting power into the transmission network (including the dedicated transmission line
connecting the Power Station with the transmission/CTU network).

 

“Intervening party” means
all entities of the First party which will intervene to the present contract, also called the Guarantor, to guarantee (“Sovereign
Guarantees”) the monthly invoices, monthly provisional invoices corresponding to the purchase of electricity by the Buyer,
all additional invoices for any reason as long as related to the terms of this contract, as well as “ALL” of
the obligations of the First Party, in reference to these presences The guarantee in question is considered to be effective during
all the duration of validity of the contract.

 

“Invoice” or “Bill”:
means either a Weekly Tariff Invoice, a Supplementary Invoice or a Procurer Invoice; “Late Payment Surcharge”: shall
have the meaning ascribed thereto in clause 11.3.4.

 

“Law”: means, in relation to this Agreement,
all Electricity Laws and by-laws in force in the country.

 

“Lenders”: means the banks,
other financial institutions, multilateral agencies, registered non-banking financial companies, mutual funds and agents or trustees
of debenture / bond holders, including their successors and assignees, who have agreed as on or before COD of the Power Station
to provide the Seller with the senior debt financing described in the Capital Structure Schedule, and any successor banks or financial
institutions to whom their interests under the Financing Agreements may be transferred or assigned; Provided that, such assignment
or transfer shall not relieve the Seller of its obligations to the Procurer under this Agreement in any manner and shall also does
not lead to an increase in the liability of any of the Procurer.

 

“Letter of Credit (LC)”
or “Revolving Letter of Credit (RLC)”: shall have the meaning ascribed thereto in clause 11.4.1.

 

“Meters” or “Metering
Systems”: Means meters used for accounting and billing of electricity in accordance with Central Electricity Authority
(Installation and Operations of Meters) Regulations, Grid Code and ABT, as amended from time to time.

 

“Maintenance Outage”: shall have the meaning
as ascribed to this term as per the provisions of the Grid Code.

 

“MCR”: means gross Power Station or Unit Maximum
Continuous Rating as defined in the Grid Code.

 

“Minimum Off-take Guarantee”: means guaranteed
off take net of self-consumption, of the total Available Energy (ex-bus) at all the times for resale.

 

“Month”: Means a period of thirty (30) days from
(and excluding) the date of the event, where applicable, else a calendar month.

 

“Weekly Bill” or “Weekly Invoice”:
Means a Weekly invoice comprising of power tariff, including incentive and penalty, as per Schedules 6 & 10 hereof.

 

“Notice to Proceed” or “NTP “:
Means the date on which the Seller shall fulfill the condition as contained in clause 3.1.2 (iii) of this Agreement in accordance
with the provisions of this Agreement.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	10

     

    

 

Power Purchase Agreement (PPA)

 

“Natural Force Majeure Event”: shall have the
meaning ascribed thereto in clause 12.3(i).

 

“Non-Natural Force Majeure Event”: shall have the meaning
ascribed thereto in clause 12.3(ii).

 

“Operating Period”: in relation to the Power
Station means the period from its COD, until the expiry or earlier termination of this Agreement in accordance with Article 2 of
this Agreement.

 

“O&M Contract (s)”: means the contract/s
entered into by the Seller with the Operator or Operators, if any.

 

“Operating Procedures”: shall have the meaning
ascribed thereto in Grid Code.

 

“Operator(s)”: means one or more contractors
appointed as operator of power generation facilities of the Power Station pursuant to an O&M contract, if any.

 

“Party” and “Parties”:
shall have the meaning ascribed thereto in the recital to this Agreement.

 

“Performance Test”: means
the test carried out in accordance with clause 1.1 of Schedule IV of this Agreement;

 

“Preliminary Default Notice”:
shall have the meaning ascribed thereto in Article 13 of this Agreement.

 

“Plant” means the integrated
MSW management, processing and disposal facility comprising the RDF Plant, the Biomethanation Plant, the Power Plant and the Inert
Management Facility to be designed, constructed, operated and maintained by Corporation in accordance with the terms and provisions
of this Agreement and in the event Corporation decides to design, construct, operate and maintain a compost plant, such facility
shall also be part of the Plant.

 

“Power Station”: means the:

 

	i.	 	RDF & Biomethanation based power generation facilities; 
	 	 	 
	ii.	 	any associated fuel handling, treatment or storage facilities of the power generation facility referred to above; 
	 	 	 
	iii.	 	any water supply, treatment or storage facilities required for the operation of the power generation facility referred to above; 
	 	 	 
	iv.	 	the ash disposal system; 
	 	 	 
	v.	 	bay/s for  transmission system in the switchyard of the power station, 
	 	 	 
	vi.	 	all the other assets, buildings/structures, equipment, plant and machinery, facilities and related assets required for the efficient and economic operation of the power generation facility. 

 

“Project”: means the Power
Station undertaken for design, financing, engineering, procurement, construction; operation, maintenance, repair, refurbishment,
development and insurance by the Seller in accordance with the terms and conditions of this Agreement;

 

“Project Documents”: means:

 

	i.	 	Engineering and Architectural plans and Construction Contracts 
	 	 	 
	ii.	 	Concession Agreement, Effluent Supply Agreement, CDM related agreements and documents; 
	 	 	 
	iii.	 	Other authorizations and clearances; 

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	11

     

    

 

Power Purchase Agreement (PPA)

 

	iv.	 	O&M contracts; 
	 	 	 
	v.	 	any other agreements plans, designated in writing as such, from time to time, jointly by the procurer and the Seller; 

 

“Prudent Utility Practices”:
means the practices, methods and standards that are generally accepted internationally from time to time by electric utilities
for the purpose of ensuring the safe, efficient and economic design, construction, commissioning, operation and maintenance of
power generation equipment of the type specified in this Agreement and which practices, methods and standards shall be adjusted
as necessary, to take account of:

 

	i.	 	operation and maintenance guidelines recommended by the manufacturers of the plant and equipment to be incorporated in the Project;
	 	 	 
	ii.	 	the requirements of Law; and
	 	 	 
	iii.	 	the physical working conditions for workers, inspectors and visitors at the Site;

 

“Quoted Tariff”: Shall mean the year wise charges
quoted by the Seller on per unit basis (refer to Schedule VIII);

 

“Renewal Option” means an
additional thirty (30) years term, tacitly renewed (discretion of Vendor), and as described in the “Term” definition,
below.

 

“Repeat Performance Test”: Shall have the meaning
ascribed thereto in Article 8.1 of this Agreement;

 

“Revised Scheduled COD”: Shall have the meaning
as ascribed thereto in clause 3.1.2 (ix) b;

 

“RPC”: Means the relevant
Regional Power Committee established by the Government of that region for a specific Region in accordance with the Electricity
Act, for facilitating integrated operation of the power system in that Region;

 

“Regional Energy Accounts”
or “REA”: Means as defined in the Grid Code and issued by the relevant RPC secretariat or other appropriate
agency for each Week and for each Month (as per their prescribed methodology), including the revisions and amendments thereof;

 

“RLDC”: Means the relevant
Regional Load Dispatch Centre as defined in the Electricity Act, in the region in which the Project is located;

 

“Scheduled COD” or “Scheduled
Commercial Operation Date”: means for Power Station, the proposed date of commissioning calculated on the basis of the
number of months from the Effective Date, as provided or such other dates from time to time, specified in accordance with the provisions
of this Agreement;

 

“Scheduled Connection Date”: shall mean the date
falling 180 days before the Scheduled COD of Power Station;

 

“Scheduled Outage”: shall have the meaning ascribed
to this term as per the provisions of the Grid Code;

 

“Scheduled Synchronization Date”:
means in relation to the Power Station, the date, which shall be maximum of Sixty (60) days prior to the Scheduled COD of the respective
Unit; (assuming 30 days period for stabilization for first synchronizing and 30 days period for trial run);

 

“Supplementary Bill”: means
a bill other than a Weekly Bill raised by any of the Parties in accordance with Article 11;

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	12

     

    

 

Power Purchase Agreement (PPA)

 

“Site”: means the land over which the Project
will be developed as provided in Schedule I.A;

 

“SLDC”: means the relevant State Load Dispatch
Centre as defined in the Electricity Laws, in the State where the Procurer's registered office is located;

 

“State Transmission Utility” or “STU”:
shall have the meaning ascribed thereto in the Electricity Act;

 

“Tariff Payment”: means the payments under Weekly
Bills as referred to in Schedule V and the relevant Supplementary Bills;

 

“Tariff”: means the tariff as computed in accordance
with Schedule VIII;

 

“Technology” means the relevant
technology for the waste to energy processes, that Corporation may, at its discretion, deem fit to use in the Project Facilities
from time to time.

 

“Tested Capacity”: in relation
to the Power Station as a whole means the results of the most recent Performance Test or Repeat Performance Test carried out in
relation to the Power Station in accordance with Article 6, Article 8 and Schedule III of this Agreement;

 

“Term” means the time period
of Thirty (30) years commencing from the Effective Date and will also include an option of an additional thirty (30) years thereafter,
tacitly renewed (Corporation’s discretion), whereby the resale of electricity shall be indexed by four and a half percent
(4.5 %) per annum, using the 30th year of the 1st period as a base for indexation for the optional period.

 

“Terminal Price”: means
the price at which the Seller will transfer back the site along with all the assets necessary to run the plant as erected by the
Seller to the First Party, at the end of the term of this Agreement. This price is the same as mentioned in the Concession Agreement
signed between the Seller and the First Party of the Municipal Solid Waste Concession Agreement, Land Lease Agreement & Supply
of Treated Sewage/Effluent Agreement;

 

“Termination Notice”: shall
mean the notice given before termination of this Agreement in accordance with relevant clauses of this Agreement;

 

“Term of the Agreement”:
shall have the meaning ascribed thereto in clause 2.1;

 

“Total Debt Amount”: means
the sum of the following amounts, expressed in US Dollars, namely:

 

	i.	 	the principal amount of the senior debt incurred by the Seller (as per the terms of the Financing Agreements) to finance the Project according to the Capital Structure Schedule which remains outstanding on the date of issuance of Substitution Notice by the Lender after taking account of any senior debt repayments which could have been made out of the Weekly Tariff Payments received by the Seller on or before the date of issuance of Substitution Notice by the Lender as per the terms provided in the Financing Agreements; and 
	 	 	 
	ii.	 	all accrued interest and financing fees payable under the Financing Agreements on the amounts referred to in (i) above from the date of the Capacity Charge payment immediately preceding the date of issuance of Substitution Notice by the Lender or, if the Capacity Charges have not yet fallen due to be paid, from the most recent date when interest and financing fees were capitalized, and 
	 	 	 
	iii.	 	if this Agreement is terminated during the Construction Period, any amounts owed to the Construction Contractor for work performed but not paid for under the Construction Contract (other than amounts falling due by reason of the Seller's default); 

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	13

     

    

 

Power Purchase Agreement (PPA)

 

“RLDC”: Means the relevant Regional Load Dispatch
Centre as defined in the Electricity Regulation, in the region in which the Project is located;

 

“Unscheduled Interchange” or “UI
“: shall have the meaning ascribed thereto in the Rules of the CERC (Terms and Conditions of tariff) Regulations as amended
or revised from time to time;

 

“Week”: means a calendar week commencing from
00:00 hours of Monday, and ending at 24:00 hours of the following Sunday;

 

“Wheeling Charges “ or “Transmission
Charges”: Are the charges paid by the Procurers to the CTU or STU or any other agency for the transfer of power from
the Power Station switchyard end to the Procurer's network.

 

		1.2	Interpretation

 

Save where the contrary is indicated, any reference in this Agreement
to:

 

		1.2.1	This Agreement shall be co-terminus with the Concession Agreement and is to be read, for any interpretation,
together with the provisions of the Municipal Solid Waste Concession Agreement, Land Lease Agreement & Supply of Treated Sewage/Effluent
Agreement.

 

		1.2.2	The capitalized terms that are used but not defined in this Agreement shall have the same meaning
as given to them in the Concession Agreement.

 

		1.2.3	A “Recital”, an “Article”, a “Schedule”
and a “paragraph/clause” shall be construed as a reference to a Recital, an Article, a Schedule and a paragraph/clause
respectively of this Agreement.

 

		1.2.4	An “affiliate” of any party shall mean a company that either directly or indirectly
controls or is controlled by or is under common control of the same person which controls the concerned party; and control means
ownership by one company of at least twenty six percent (26%) of the voting rights of the other company.

 

		1.2.5	An “encumbrance” shall be construed as a reference to a mortgage, charge, pledge,
lien or other encumbrance securing any obligation of any person or any other type of preferential arrangement (including, without
limitation, title transfer and retention arrangements) having a similar effect.

 

		1.2.6	“indebtedness” shall be construed so as to include any obligation (whether incurred
as principal or surety) for the payment or repayment of money, whether present or future, actual or contingent;

 

		1.2.7	A “person” shall be construed as a reference to any person, firm, company, corporation,
society, trust, government, state or agency of a state or any association or partnership (whether or not having separate legal
personality) of two or more of the above and a person shall be construed as including a reference to its successors, permitted
transferees and permitted assigns in accordance with their respective interests.

 

		1.2.8	The “winding-up”, “dissolution”, “insolvency”,
or “reorganization” of a company or corporation shall be construed so as to include any equivalent or analogous
proceedings under the Law of the jurisdiction in which such company or corporation is incorporated or any jurisdiction in which
such company or corporation carries on business including the seeking of liquidation, winding-up, reorganization, dissolution,
arrangement, protection or relief of debtors.

 

		1.2.9	Words importing the singular shall include the plural and vice versa.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	14

     

    

 

Power Purchase Agreement (PPA)

 

		1.2.10	This Agreement itself or any other agreement or document shall be construed as a reference to this
or to such other agreement or document as it may have been, or may from time to time be, amended, varied, novated, replaced or
supplemented.

 

		1.2.11	A time of day shall, save as otherwise provided in any agreement or document be construed as a
reference to the Standard Time of the country.

 

		1.2.12	Different parts of this Agreement are to be taken as mutually explanatory and supplementary to
each other and if there is any inconsistency between or among the parts of this Agreement, they shall be interpreted in a harmonious
manner so as to give effect to each part.

 

		1.2.13	The tables of contents and any headings or sub-headings in this Agreement have been inserted for
ease of reference only and shall not affect the interpretation of this Agreement.

 

		1.2.14	All interest payable under this Agreement shall accrue from day to day and be calculated on the
basis of a year of three hundred and sixty five (365) days.

 

		1.2.15	The words “hereof or “herein”, if and when used in this Agreement
shall mean a reference to this Agreement.

 

		2.	ARTICLE
2: TERM OF AGREEMENT

 

		2.1	Effective Date and Term of Agreement

 

This Agreement shall come into effect from
the Effective Date. This Agreement shall be valid for a term commencing from the Effective Date until the Expiry Date (“Term
of Agreement”) unless terminated earlier pursuant to clause 2.2. Upon the occurrence of the Expiry Date, this Agreement
shall, subject to clause 18.9, automatically tacitly renews to the renewal option.

 

		2.2	Early Termination

 

This Agreement shall terminate before the
Expiry Date: 

 

		 i.	if either the Procurer or Seller exercises a right
to terminate, pursuant to clause 3.3.1, clause 3.3.2, clause 3.3.3 and clause 4.4.3 of this Agreement or any other provision of
this Agreement; or

 

		ii.	in such other circumstances as the Seller and all
the Procurer may agree, in writing.

 

		2.3	Terminal Price payment

 

The Terminal Price payment to be made by Procurer (if any) to Seller,
as mentioned in the clause 1.1 should be paid within ten (10) days from the last day of Term of the Agreement, or the renewal option.

 

		2.4	Survival

 

The expiry or termination of this Agreement
shall not affect accrued rights and obligations of the Parties under this Agreement, including the right to receive Liquidated
Damages (if any) as per the terms of this Agreement, nor shall it affect any continuing obligations for which this Agreement provides,
either expressly or by necessary implication, the survival of, post its expiry or termination.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	15

     

    

 

Power Purchase Agreement (PPA)

 

		3.	ARTICLE
3: CONDITIONS SUBSEQUENT TO BE SATISFIED BY THE SELLER AND THE PROCURER

 

		3.1	Satisfaction
of conditions subsequent by the Seller and the Procurer

 

3.1.1               A
The Seller shall have the option to change the Unit configuration after the Effective Date till NTP (Notice to Proceed), provided
that Seller submits the undertaking that the changed Unit configuration meets all the conditions specified in Schedule III and
the changed Unit configuration meets all Functional Specifications. Any additional cost arising out of the changed Unit configuration
shall be to the account of the Seller and no adjustment in the Tariff will be permitted. 

 

3.1.2               The
Seller agrees and undertakes to duly perform and complete the following activities within (i) Three Months from the Effective
Date or (ii) Four Months from the date of issue of Letter of Intent, whichever is later, unless such completion is affected
due to the Procurer's failure to comply with their obligations under clause 3.1.3 of this Agreement or by any Force Majeure
event or if any of the activities is specifically waived in writing by the Procurers jointly:

 

		i.	the Seller shall apply for the Initial Consents to as mentioned
in Schedule II. If all of the permits are not granted by the First Party, as the First Party has already signed these presences
and are the responsible entities of issuing same (permits), the default shall be considered as a premature Breach of Contract,
hereinabove named, clause 2.2, as “Early Termination”, and the First Party (Procurer) shall be subject to the
liability of said prejudice, as agreed to in the Municipal Solid Waste Concession Agreement, Land Lease Agreement & Supply
of Treated Sewage/Effluent Agreement;

 

		ii.	the Seller shall:

 

		a)	award the Engineering, Procurement and Construction
contract (“EPC” contract) or the fabrication contract for boiler, turbine and generator (“BTG”),
for the Project and shall give to such contractor an irrevocable notice to proceed, and

 

		b)	The Seller shall send a written notice to the Procurer
indicating the Contracted Capacity and Gross Capacity for the each Unit and for the Power Station as a whole expressed in MW and
furnished the undertaking as per clause 3.1.1.

 

		iii.	the Seller shall make available to the Procurer the data
with respect to the Project for design and fabrication of the interconnection Facilities and Transmission Facilities;

 

		iv.	the Seller shall finalize the specific delivery point for
supply of power in consultation with the Procurer;

 

		v.	where the Seller has not exercised its option to change
unit configuration the Seller shall send a written notice to the Procurer indicating that:

 

		a)	the Scheduled COD shall be as per the original Scheduled
COD, or

 

		b)	it intends to propone the Scheduled COD, to be established
after the obtention of all permits and clearances for the project mentioned herein (hereinafter referred to as “Revised
Scheduled COD”).

 

		vi.	where the Seller has exercised its option to change unit
configuration the Seller shall send a written notice to the Procurer indicating the changing of the Scheduled COD.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	16

     

    

 

Power Purchase Agreement (PPA)

 

3.1.3             The Procurers shall ensure that the following activities
are completed within the time period mentioned below:

 

Obtaining all permits and clearances, as referenced
in Schedule II, from the appropriate regulatory divisions of government, within two (2) months after official deposit of pertinent
project plans and supporting documentation by the Seller.

 

3.1.4             Joint
responsibilities of the Procurer and the Seller:

 

The
Procurer and Seller shall jointly appoint the Independent Engineer at the cost of Seller, for the purposes of carrying out
the functions as specified in clause 4.7.1, Article 6, Article 8 and Article 12, herein within a period of eight (8) months
from the Effective Date of these presences.

 

		3.2	Progress Reports

 

The Seller and the Procurer shall notify one
another in writing at least once every two (2) weeks on the progress of the project, until completion.

 

		3.3	Consequences of non-fulfillment of conditions under
clause 3.1

 

3.3.1             If
any of the conditions specified in clause 3.1.2 is not duly fulfilled by the Seller even within six (6) Months after the time
specified under clause 3.1.2, then the Procurer reserves the right to execute the “Procedure for cases of Seller Event of
Default” of clause 13.3.

 

3.3.2             In case of inability of the Seller
to fulfill the conditions specified in clause 3.1.2 due to any Force Majeure event, the time period for fulfillments of the Condition
Subsequent as mentioned in clause 3.1.2 and clause 3.1.3, shall be extended for the period of such Force Majeure event, subject
to a maximum extension period of one hundred and twenty days (120) days, continuous or non-continuous in aggregate. Thereafter,
this Agreement may be terminated by the Seller by giving a notice, in writing, to the other Party.

 

Similarly, in case of inability of the Procurer
to fulfill the conditions specified in clause 3.1.3 due to any Force Majeure event, the time period for fulfillment of the Condition
Subsequent as mentioned in clause 3.1.2 and clause 3.1.3, shall be extended for the period of such Force Majeure event, subject
to a maximum extension period of one hundred and twenty days (120) days, continuous or non-continuous in aggregate. Thereafter,
this Agreement may be terminated by the Seller by giving a Termination Notice, in writing, to the other Party.

 

3.3.3              No Tariff adjustment shall be allowed
on account of any extension of time arising under any of the sub - articles of clause 3.3. Provided that due to the provisions
of clause 3.3.3, any increase in the time period for completion of Conditions Subsequent mentioned under clause 3.1.2 and 3.1.3,
shall also lead to an equal increase in the time period for Scheduled COD and Scheduled Connection Date.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	17

     

    

 

Power Purchase Agreement (PPA)

 

		4.	ARTICLE
4: DEVELOPMENT OF THE PROJECT

 

		4.1	The Seller's obligation to build, own and operate the Project

 

4.1.1             Subject to the terms and conditions of this Agreement, the
Seller undertakes to be responsible, at Seller's own cost, for:

 

		a)	executing the Project in a timely manner so as to
enable the Power Station as a whole to be Commissioned;

 

		b)	owning the Project throughout the term and option of
this Agreement free and clear of encumbrances, except those expressly permitted by Article 16 and financial obligations with Lending
institutions;

 

		c)	procure the requirements of electricity at the Project
(including construction, commissioning and start-up power) and to meet in a timely manner all formalities for getting such a supply
of electricity;

 

		d)	provide on a timely basis relevant information on Power
Station specifications which may be required for interconnecting system with the transmission system;

 

		e)	fulfilling all other obligations undertaken by him
under this Agreement.

 

		f)	shall be responsible for procuring the Interconnection
and Transmission Facilities to enable the Power Station to be connected to the Grid System.

 

		4.2	Procurer's obligation

 

Subject to the terms and conditions of this
Agreement, the Procurer:

 

		a)	shall be responsible
for facilitating the procurement of the Interconnection and Transmission Facilities by the Seller to enable the Power Station
to be connected to the Grid System;

 

		b)	shall ensure
that the Seller is provided an electrical connection for reasonable construction, commissioning and start up power at the Project;

 

		c)	shall make all
reasonable arrangements for the evacuation of the Infirm Power from the Power Station; subject to the availability of transmission
lines and

 

		d)	fulfilling obligations undertaken by them under this
Agreement.

 

		4.3	Purchase and sale of Energy

 

4.3.1             Subject
to the terms and conditions of this Agreement, the Seller undertakes to sell to the Procurer, and the Procurer undertakes to purchase
and pay the Tariff (de facto “Take-or-Pay” (for full face value) basis), as documented in Schedule VIII, for
the total net Available Energy of the Power Station, generated and delivered at any time throughout the term of this Agreement.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	18

     

    

 

Power Purchase Agreement (PPA)

 

		4.4	Right to Available Energy

 

4.4.1             Subject to other provisions of this Agreement,
the net energy available at the Grid shall at all times be for the exclusive benefit of the Procurer and the Procurer shall have
the exclusive right to purchase such Available Energy from the Seller. The Seller shall not grant to any third party or allow any
third party to obtain any entitlement to such Available Energy.

 

		4.5	Extensions of time

 

4.5.1             In
the event that:

 

		a)	the Seller is prevented from performing its obligations
under clause 4.1.1 (b) by the stipulated date, due to any Procurer Event of Default; or

 

		b)	the Power Station cannot be Commissioned by its Scheduled
Commercial Operations Date because of Force Majeure Events.

 

the Scheduled Commercial Operations Date, the
Scheduled Connection Date and the Expiry Date shall be deferred, subject to the limit prescribed in clause 4.5.3, for a reasonable
period but not less than 'day for day' basis, to permit the Seller through the use of due diligence, to overcome the effects of
the Force Majeure Events affecting the Seller or in the case of the Procurer's Event of Default, till such time such default is
rectified by the Procurer.

 

4.5.2             If the Parties have not on how long
the Scheduled Commercial Operations Date, the Scheduled Connection Date or the Expiry Date should be deferred by, any Party may
raise the dispute to be resolved in accordance with the Arbitration rules hereunder stipulated.

 

4.5.3             In case of extension occurring
due to reasons specified in clause 4.5.l. (a), the original Scheduled Commercial Operations Date of the Power Station as a
whole, would not be extended by more than one (1) year or the date on which the Seller elects to terminate this Agreement
(premature termination of contract with prejudice), whichever is earlier.

 

As a result of such extension, the date newly determined shall be
deemed to be the Scheduled Commercial Operations Date for the purposes of this Agreement.

 

		4.6	Liquidated damages for delay due to Procurer Event of
Default and Non Natural Force Majeure Events and Natural Force Majeure Events

 

		4.6.1	If

 

		a)	Power Station cannot be commissioned by its Scheduled
Commercial Operations Date, due to a Procurer Event of Default or due to Non Natural Force Majeure Event (or Natural Force Majeure
affecting the Procurer) provided such Non Natural Force Majeure Event (or Natural Force Majeure affecting the Procurer) has continued
for a period of more than three (3) continuous or non-continuous Months; or

 

		b)	Power Station is available for conducting Commissioning
Tests and is anticipated to be capable of duly completing the Commissioning Tests as certified by the Independent Engineer, but
the said Commissioning Tests are not undertaken or completed due to such Procurer Event of Default or due to Non Natural Force
Majeure Event (or Natural Force Majeure affecting the Procurer) provided such Non Natural Force Majeure Event (or Natural Force
Majeure affecting the Procurer) has continued for a period of more than three (3)
continuous or non-continuous Months:

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	19

     

    

 

Power Purchase Agreement (PPA)

 

4.6.2             Such
Unit shall, until the effects of the Procurer Event of Default or of Non Natural Force Majeure Event (or Natural Force Majeure
affecting the Procurer) no longer prevent the Seller from undertaking a Commissioning Test, be deemed too been Commissioned with
effect from the Scheduled COD without taking into account delay due to such Procurer Event of Default or Non Natural Force Majeure
Event (or Natural Force Majeure affecting the Procurer) and shall be treated as follows.

 

		a)	In
case of delay on account of the Procurer Event of Default, the Procurer shall make payment to the Seller of an amount equal
to:

 

		i.	Deemed
power generation at 100% of the net available for resale to the Procurer, multiplied by the number of days of default,
plus

 

		ii.	The
loss of minimum MSW tipping fee guarantee by the Procurer (First Party) as stipulated in the Municipal Solid Waste Concession
Agreement, Land Lease Agreement & Supply of Treated Sewage/Effluent Agreement multiplied by the number of days of default.

 

Nota bene: i + ii = Amount payable to Seller by Procurer

 

		b)	In case of delay on account of any Natural Force Majeure
Event, the Procurer shall not be obliged to make any payment to the Seller.

 

4.6.3             In every case referred to in clause
4.6.1 hereinabove, the Seller shall undertake a Commissioning Test as soon as reasonably practicable and in no event later than
two (2) weeks or such longer period as mutually agreed between the Seller and the Procurer after the point at which it is no longer
prevented from doing so by the effects of Force Majeure Events or Procurer Event of Default (as appropriate).

 

		4.7	Limit on amounts payable due to default

 

4.7.1             The Parties expressly agree that the
Procurer's only liability for any loss of profits or any other loss of any other kind or description whatsoever, suffered by the
Seller by reason of the Procurer's failure to meet its obligations under clause 4.2(a) to clause 4.2(d) shall be to pay the Seller
the amounts specified in clause 4.6 and Article 13.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	20

     

    

 

Power Purchase Agreement (PPA)

 

		5.	ARTICLE
5: CONSTRUCTION

 

		5.1	Seller's Construction Responsibilities

 

The Seller shall be responsible for designing,
constructing, erecting, commissioning, completing and testing the Power Station in accordance with the following, it being clearly
understood that in the event of inconsistency between two or more of the following, the order of priority as between them shall
be the order in which they are placed, with applicable law in the first:

 

		a)	applicable Law including MSW (Management & Handling)
Rules;

 

		b)	the Grid Code;

 

		c)	the terms and conditions of this Agreement;

 

		d)	the Functional Specifications; and

 

		e)	Prudent Utility Practices.

 

Notwithstanding anything to the contrary contained
in this PPA, the Seller shall ensure that the technical parameters or equipment limits of the Project shall always be subject to
the requirements as specified in points (a) to (e) above and under no event shall over-ride or contradict the provisions of this
Agreement and shall not excuse the Seller from the performance of his obligations under this Agreement.

 

		5.2	The Site

 

On and from the Effective Date, the Seller
shall be deemed, on the basis of the provisions of project proposal, to have had sufficient opportunity to investigate the Site
(including but not limited to its geological condition, on the Site, the adequacy of the road and rail links to the Site and the
availability of adequate supplies of water) and accepts full responsibility for its condition and that it shall not be relieved
from any of its obligations under this Agreement or be entitled to any extension of time or financial compensation by reason of
the unsuitability of the Site for whatever reason.

 

		5.3	Information Regarding Interconnection Facilities

 

The Procurer shall provide the Seller, on a
timely basis, all information with regard to the Interconnection and Transmission Facilities as is reasonably necessary to enable
the Seller to design, install and operate all interconnection plant and apparatus on the Seller's side of the Interconnection Point.

 

		5.4	Quality of Workmanship

 

The Seller shall ensure that the Power Station
is designed, built and completed in a good workmanlike manner using sound engineering construction practices and using only materials
and equipment that are new and of international utility grade quality such that, the useful life of the Power Station will be at
least till the Expiry Date.

 

The Seller shall ensure that design, construction
and testing of all equipment, facilities, components and systems of the Project shall be in accordance with Autonomous Island of
Grande Comore, Union of the Comoros Standards and Codes issued by the Bureau of Autonomous Island of Grande Comore, Union of the
Comoros Standards and/or internationally recognized Standards and Codes, such as:

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	21

     

    

 

Power Purchase Agreement (PPA)

 

	i.	 	American National Standards Institute (ANS) 
	ii.	 	American Society of Testing and Materials (ASTM) 
	iii.	 	American Society of Mechanical Engineers (ASME) 
	iv.	 	American Petroleum Institute (API) 
	v.	 	Standards of the Hydraulic Institute, USA 
	vi.	 	International Organization for Standardization (ISO) 
	vii.	 	Japanese Industrial Standards (JIS) 
	viii.	 	Tubular Exchanger Manufacturer's Association (TEMA) 
	ix.	 	American Welding Society (AWS) 
	x.	 	National Electrical Manufacturers Association (NEMA) 
	xi.	 	National Fire Protection Association (NFPA) 
	xii. 	 	International Electro-Technical Commission (AEC) 
	xiii.	 	Expansion Joint Manufacturers Association (EJMA) 
	xiv.	 	Heat Exchange Institute (HEI) 
	xv.	 	American Water Works Association (AWWA) 

 

Other international standards, established
to be equivalent or superior to the above standards shall also be acceptable. However, in the event of any conflict between the
requirements of the international codes and standards and the requirements of the country’s standards and regulations, the
latter shall prevail.

 

		5.5	Consents

 

The Seller shall be responsible for furnishing
all documents and plans required for developing, financing, constructing, operating and maintenance of the Project. For the avoidance
of doubt, it is clarified that the Procurer shall be responsible for the issuance of permits and clearances, as stipulated in clause
3.1.3 above. The Seller shall be responsible for maintaining and renewing the Consents and for fulfilling all conditions specified
therein.

 

		5.6	Construction Documents

 

The Seller shall retain at the Site and make
available for inspection to the Procurer at all reasonable times copies of the results of all tests specified in Schedule IV hereof.

 

		5.7	Co-ordination of Construction Activities

 

5.7.1             Before the tenth (10th)
day of each Month, during the Construction Period the Seller shall prepare and submit to the Procurer as well as Authorized Representative
a monthly progress report, in the Agreed Form.

 

The Seller and all the Procurer shall designate
from time to time, by giving a written notice to the other party up to five (5) of its employees who shall be responsible for coordinating
all construction activities relating to the Project and who shall have access at all reasonable times to the other party's land
for the purpose of apprising the progress of the work being carried on, subject to such designated persons or the party appointing
them giving reasonable notice to the other party of such visit and subject to their complying with all reasonable safety procedures.
The Procurer will have to give a written notice to the Seller of at least one (1) day, to visit the physical premises of the Complex.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	22

     

    

 

Power Purchase Agreement (PPA)

 

		6.	ARTICLE
6: SYNCHRONISATION, COMMISSIONING AND COMMERCIAL OPERATION

 

		6.1	Synchronization

 

6.1.1             The Seller shall give the Procurer
and RLDC at least sixty (60) days advance preliminary written notice and at least thirty (30) days advance final written notice,
of the date on which it intends to synchronize Power Station to the Grid System.

 

6.1.2             Subject to clause 6.1.1, Power
Station may be synchronized by the Seller to the Grid System when it meets all connection conditions prescribed in any Grid Code
then in effect and otherwise meets all other country legal requirements for synchronization to the
Grid System. 

 

		6.2	Commissioning

 

6.2.1             The Seller shall be responsible for
ensuring that Power Station is commissioned in accordance with Schedule IV at its own cost.

 

6.2.2             The Seller shall give the Procurer
and the Independent Engineer not less than ten (10) days prior written notice of Commissioning Test of Power Station.

 

6.2.3             The Seller, the Procurer and the Independent
Engineer shall each designate qualified and authorized representatives to witness and monitor Commissioning Test of Power Station.

 

6.2.4             Testing and measuring procedures applied
during Commissioning Test shall be in accordance with the codes, practices and procedures mentioned in Schedule IV of this Agreement.

 

6.2.5             Within five (5) days of a Commissioning
Test, the Seller shall provide the Procurer and the Independent Engineer with copies of the detailed Commissioning Test results.
Within five (5) days of receipt of the Commissioning Test results, the Independent Engineer shall provide to the Procurer and the
Seller in writing, his findings from the evaluation of Commissioning Test results, either in the form of Final Test Certificate
certifying the matters specified in clause 6.3.1 or the reasons for non-issuance of Final Test Certificate.

 

		6.3	Commercial Operation

 

6.3.1             Power Station shall be commissioned
following the date when the Procurer and the Seller receive a Final Test Certificate of the Independent Engineer stating that:

 

		a)	the Commissioning
Tests have been carried out in accordance with Schedule IV, and are acceptable to him; and

 

		b)	the results of the Performance Test show that the Power Station's Tested Capacity, is not
                                                                                 less than ninety five (95) percent of its Minimum Capacity (net after self-consumption), as existing on the Effective Date or
                                                                                 in case the Seller has exercised the option under clause 3.1.1 the Contracted Capacity so finalized.

 

6.3.2             If the Power Station fails a Commissioning
Test, the Seller may retake the relevant test, within a reasonable period after the end of the previous test, with three (3) day's
prior written notice to the Procurer and the Independent Engineer. Provided however, the Procurer shall have a right to require
deferment of any such re-tests for a period not exceeding fifteen (15) days, without incurring any liability for such deferment,
if the Procurer is unable to provide evacuation of power to be generated, due to reasons outside the reasonable control of the
Procurer or due to inadequate demand in the Grid.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	23

     

    

 

Power Purchase Agreement (PPA)

 

6.3.3             The
Seller may retake the Performance Test by giving at least fifteen (15) days advance notice in writing to the Procurer, up to eight
(8) times, during a period of one hundred and twenty (120) days (“Initial Performance Retest Period”) from
Power Station's COD in order to demonstrate an increased Tested Capacity to meet the minimum requirements. Provided however, the
Procurer shall have a right to require deferment of any such re-tests for a period not exceeding fifteen (15) days, without incurring
any liability for such deferment, if the Procurer are unable to provide evacuation of power to be generated, due to reasons outside
the reasonable control of the Procurer or due to inadequate demand in the Grid.

 

6.3.4             (i)
If Power Station's Tested Capacity after the most recent Performance Test mentioned in clause 6.3.3 has been conducted, is less
than its Minimum Capacity (3.8 MW Net) as existing on the Effective Date or in case the Seller has exercised the option under
clause 3.1.1, the Capacity so finalized after testing will be the final capacity for the Minimum Capacity requirements.

 

6.3.5             If
Power Station's Tested Capacity as at the end of the Initial Performance Retest Period or the date of the eighth (8th)
Performance Test mentioned in clause 6.3.3, whichever is earlier, is found to be more than its Minimum Capacity (3.8 MW Net) as
existing on the Effective Date or in case the Seller has exercised the option under clause 3.1.1., the capacity as so defined,
the tested capacity shall be deemed to be the Power Station's Capacity.

 

		6.4	Costs Incurred

 

The Seller expressly agrees that all costs
incurred by him in synchronizing, connecting, commissioning and/or testing or retesting Power Station shall be solely and completely
to his account and the Procurer's liability shall not exceed the amount of the Energy Charges payable for such power output, as
set out in Schedule VIII.

 

		7.	ARTICLE
7: OPERATION AND MAINTENANCE

 

The Parties shall comply with the provisions of the applicable Law
including, in particular the Grid Code.

 

		8.	ARTICLE
8: CAPACITY, AVAILABILITY AND DISPATCH

 

		8.1	Repeat Performance Tests

 

8.1.1             The
Procurers may from time to time during the Operating Period, but only if the available capacity has not been one hundred per cent
(100%) of the Minimum Capacity of the Power Station (excluding the planned outage for capital maintenance in consultation with
the Procurer) even for one continuous period of at least three (3) hours during any three continuous months, require the Seller
to demonstrate the Power Station's tested capacity by carrying out a further Performance Test (a “Repeat Performance
Test”) in accordance with this clause 8.1. A Repeat Performance Test shall be carried out in accordance with
Schedule IV, save that the test shall last twenty-four (24) hours instead of seventy-two (72) hours. Provided that if the tested
capacity after such test is less than ninety five percent (95 %) of the minimum capacity as existing on the Effective Date (or
in case the Seller has exercised the option under clause 3.1.1, the Minimum Capacity as so finalized) of the Commissioned Units.

 

8.1.2             The Procurer shall give the Seller
not less than seven (7) days' advance written notice of the time when a Repeat Performance Test of the Power Station is to begin.
A Repeat Performance Test may not be scheduled for any period when the Power Station is due to undergo a Scheduled Outage.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	24

     

    

 

Power Purchase Agreement (PPA)

 

8.1.3             The Procurer and Seller shall jointly
appoint the Independent Engineer to monitor the Repeat Performance Test and to certify the results.

 

8.1.4             If the Seller wishes to take Power
Station, out of service for repair before a Repeat Performance Test, it shall inform the Procurer in writing before its scheduled
start of the repairs and the estimated time required to complete the repairs. The Parties shall then schedule a Maintenance Outage
in accordance with the Grid Code to enable the Seller to carry out those repairs and in such a case, the Procurer, requiring the
Repeat Performance Test, shall defer the Repeat Performance Test until Power Station is returned to service following that Maintenance
Outage.

 

8.1.5             The
Seller, the Procurer and the Independent Engineer shall each have the right to designate qualified and authorized
representatives (but are not obligated to do so) to monitor the Repeat Performance Test.

 

8.1.6             Testing and measurement procedures
applied during the Repeat Performance Test shall be in accordance with the codes, practices of procedures as generally/normally
applied for the Performance Tests (refer to Schedule IV).

 

8.1.7             Within five (5) days of a Repeat Performance
Test, the Seller shall provide to the Procurer and the Independent Engineer with copies of the detailed test results.

 

8.1.8             Within five (5) days of receipt of
the Commissioning Test results, the Independent Engineer shall provide to the Procurer and the Seller in writing, his findings
from the evaluation of Commissioning Test results, either in the form of Final Test Certificate certifying the matters specified
in clause 6.3.1 or the reasons for non-issuance of Final Test Certificate.

 

8.1.9             Within one (1) Month of the date by
which the Power Station has been commissioned, the Seller shall conduct a Performance Test of the Power Station (hereinafter referred
to as “Power Station Performance Test”) whereafter the provisions of clause 8.2 shall apply. A Power
Station Performance Test shall be carried out in accordance with clause 1.1 of Schedule IV, save that the test shall last
twenty-four (24) hours instead of seventy-two (72) hours.

 

		8.2	Availability

 

The Seller shall comply with the provisions
of the applicable Law regarding Availability including, in particular, to the provisions of the Grid Code relating to intimation
of Availability and the matters incidental thereto.

 

		8.3	Dispatch

 

The Power Station shall enjoy a must-run status
and accordingly, no other merit order will apply, for the term of the contract and renewal option, thereof.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	25

     

    

 

Power Purchase Agreement (PPA)

 

		9.	ARTICLE
9: METERING AND ENERGY ACCOUNTING

 

		9.1	Meters

 

For installation of Meters, Meter testing,
Meter calibration and Meter reading and all matters incidental thereto, the Seller and the Procurer shall follow and be bound by
the Central Electricity Authority (Installation and Operation of Meters) Regulations, the Grid Code and ABT as amended and revised
from time to time. In addition, the Seller shall also allow and facilitate CTU in installation of one set of required main and
standby special energy meters for accurate recording of energy supplied by Seller. For these CTU meters (110V, 1A, 4-wire), the
Seller shall provide the required connection from EHV current transformers/ bushing CTs/ voltage transformers/ CVTs on EHV side
of all generator-transformers, station transformers and outgoing lines, of meter accuracy of 0.2 class or better. The Seller may
install any further meters for its own comfort at its own cost.

 

		10.	ARTICLE 10: INSURANCES

 

		10.1	Insurance

 

The Seller shall effect and maintain or cause
to be affected and maintained during the Construction Period and Operating Period, Insurances against such risks, with such deductibles
and with such endorsements and co-insured(s), which the Prudent Utility Practices would ordinarily merit maintenance of and as
required under the Financing Agreements.

 

		10.2	Application of Insurance Proceeds

 

Save as expressly provided in this Agreement
or the Insurances, the proceeds of any insurance claim made due to loss or damage to the Project or any part of the Project shall
be first applied to reinstatement, replacement or renewal of such loss or damage of the project.

 

If an Event renders the Project no longer economically
and technically viable and the insurers under the Insurances make payment on a “total loss” or equivalent basis,
the Procurer shall have no claim on such proceeds of such Insurance.

 

		10.3	Effect on liability of the Procurer

 

Notwithstanding any liability or obligation
that may arise under this Agreement, any loss, damage, liability, payment, obligation or expense which is insured or for which
the Seller can claim compensation, shall be paid by the Insurer to the Seller, and the Procurer agrees and endorses same, by these
presences.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	26

     

    

 

Power Purchase Agreement (PPA)

 

		11.	ARTICLE 11: BILLING AND PAYMENT

 

		11.1	General

 

From the COD of the Power Station, Procurer
shall pay the Seller the Weekly Tariff Payment, on or before the Due Date, comprising of Tariff for every Contract Year, determined
in accordance with this Article 11 and Schedule VIII. All Tariff payments by Procurer shall be in United States Dollars.

 

Provided however, if the
Procurer avails of any Electrical output from the Seller prior to the Commercial Operation Date (“Infirm
Power”) of the Unit, then also Procurer shall be liable to pay Energy Charges (as applicable for the Contract Year
in which the Infirm Power is supplied or next Contract Year in case no Energy Charges are mentioned in such Contract Year),
for Infirm Power generated by Power Station. The quantum of Infirm Power generated by Power Station synchronized but not have
been put on COD shall be computed from the energy accounting and audit meters installed at the Power Station as per Central
Electricity Authority Regulations.

 

		11.2	Delivery and content of Weekly Bills

 

11.2.1             The Seller shall issue to Procurer
a Weekly Bill.:

 

11.2.2             Each Weekly Bill and Provisional
Bill shall include:

 

		 i.	Energy account for the relevant Week as per REA for
Weekly Bill and RLDC's daily energy account for Provisional Bill;

 

		ii.	the Seller's computation of the Weekly Tariff Payment
in accordance with Schedules VI and X; and

 

		iii.	supporting data, documents and calculations in accordance
with this Agreement

 

		11.3	Payment of Weekly Bills

 

11.3.1             Procurer shall pay the amount payable
under Weekly Bill on the Due Date to such account of the Seller by “Direct Deposit” or against a “Revolving
Letter of Credit” issued by the Procurer for the Benefit of the Seller as described in clause 11.4 (if Direct Deposit
is not effected), in accordance with clause 11.3.3 below.

 

All payments made by the Procurer shall be by appropriate order
of priority:

 

		a)	towards Late Payment Surcharge, payable by the Procurer,
if any;

 

		b)	towards earlier unpaid Weekly Bill, if any, and

 

		c)	towards the then current Weekly Bill.

 

11.3.2             All payments required to be made
under this Agreement shall only include any deduction or set off for deductions required by the Law; and amounts claimed by the
Procurer from the Seller, through an invoice duly acknowledged by the Seller, to be payable by the Seller, and not disputed by
the Seller within thirty (30) days of receipt of the said invoice and such deduction or set-off shall be made to the extent of
the amounts not disputed. It is clarified that the Procurer shall be entitled to claim any set off or deduction under this clause,
after expiry of the said thirty (30) day period.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	27

     

    

 

Power Purchase Agreement (PPA)

 

Provided further,
the maximum amounts that can be deducted or set-off by the Procurer under this Article in a Contract Year shall not exceed twenty
(20) percent of the weekly billing.

 

11.3.3             The Seller shall open a bank account
as designated by Lenders (the “Designated Account”), and shall not be refuted by Procurer (First Party), for
all Tariff Payments to be made by Procurer to the Seller, and notify Procurer of the details of such account at least ninety (90)
days before the dispatch of the first Weekly Bill by the Procurer. Procurer shall instruct their respective bankers to make all
payments under this agreement to the Designated Account and shall notify the Seller of such instructions on the same day. Procurer
shall also designate a bank for payments to be made by the Seller (including Supplementary Bills) to Procurer and notify the Seller
of the details of such account ninety (90) days before the COD of the Power Station.

 

11.3.4             In
the event of delay in payment of a Weekly Bill by Procurer beyond its Due Date weekly billing, a Late Payment Surcharge
shall be payable by Procurer to the Seller at the rate of twenty two (22) percent APR (“Annual Percentage
Rate”), on the amount of outstanding payment, calculated on a day to day basis (and compounded with daily
interest), for each day of the delay.

 

		11.4	Payment Mechanism

 

11.4.1             Irrevocable Revolving Letter of Credit:

 

Procurer shall provide to the Seller, in respect
of payment of its Weekly Bills, an unconditional, revolving and irrevocable letter of credit (Letter of Credit - RLC), opened
and maintained by Procurer, which may be drawn upon by the Seller in accordance with clauses 11.4.1.1 through 11.4.1.7. The Procurer
shall provide the Seller draft of the Letter of Credit proposed to be provided to the Seller for final review and critiques, which
shall adhere to the essence of these presences.

 

11.4.1.1             Not later than three (3) Months following
the signature of these presences, Procurer shall through its scheduled bank (reference clause 11.3.3) open a Letter of Credit in
favour of the Seller (Beneficiary), to be made operative from a date prior to the Due Date of its first Weekly Bill under this
Agreement. The Irrevocable Revolving Letter of Credit shall have a term of twelve (12) Months, renewed every year for the duration
of the term and renewal option thereof, and shall be replenished to its face value four (4) times per annum, for an amount:

 

		i.	for the first
Contract Year, equal to one point one (1.1) times the estimated average yearly billing based on 100% of the Gross Energy production
(Megawatts) multiplied by 1000 kW per Megawatt by twenty-four (24) hours per day multiplied by three hundred and sixty-five (365)
days per year multiplied by the Tariff payment of the first year, and

 

MW-h x 1000 kW/MW x 24h/day x 365 day/year
x y (Annex 10) x 1.5 = LCR 

 

		ii.	for each subsequent
Contract Year, equal to the one point one (1.1) times the average of the Yearly Tariff Payments of the previous Contract Year
(refer to Schedule VIII).

 

Provided that the procurer has not effected
a Direct Deposit to the Seller’s designated account for payment of its weekly invoice, the Seller shall draw upon such Irrevocable
Revolving Letter of Credit immediately thereafter for the payment of the relevant Weekly Bill, as further elaborated in clause
11.4.1.3.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	28

     

    

 

Power Purchase Agreement (PPA)

 

Provided further that if at any time, such
Irrevocable Revolving Letter of Credit amount falls short of the amount specified in clause 11.4.1.1 or clause 11.4.1.7 otherwise
than by reason of drawal of such Letter of Credit by the Seller, the Procurer shall restore such shortfall within seven (7) days.

 

11.4.1.2             Procurer shall cause the scheduled
bank issuing the Irrevocable Revolving Letter of Credit to intimate the Seller, in writing regarding establishing of such irrevocable
Revolving Letter of Credit.

 

11.4.1.3             If
Procurer fails to pay a Weekly Bill or part thereof within and including the Due Date, then, subject to clause 11.3.3, the
Seller may draw upon the Letter of Credit, and accordingly the bank shall pay without any reference or instructions from the
Procurer, an amount equal to such Weekly Bill or part thereof plus Late Payment Surcharge, if applicable, in accordance with
clause 11.3.4 above, by presenting to the scheduled bank issuing the Letter of Credit, the following documents:

 

		  i.	a copy of the Weekly Bill which has remained unpaid
by such Procurer;

 

		 ii.	a certificate from the Seller to the effect that the
bill at item (i) above, or specified part thereof, is in accordance with the Agreement and has remained unpaid beyond the Due
Date; and

 

		iii.	Calculations of applicable Late Payment Surcharge,
if any.

 

Further, on the occurrence of such an event
as envisaged herein, the Seller shall immediately inform the Procurer of the said failure of the Procurer to pay the Weekly Bill
or part thereof and shall send regular updates to the Procurer containing details of the amount claimed by the Seller, as per the
provisions of this clause and payments made by the Procurer pursuant to such claim.

 

For the avoidance of doubt it is clarified
that the Seller shall not be entitled to drawdown on the Letter of Credit for any failure of Procurer to pay a Supplementary Bill.

 

11.4.1.5             Procurer shall ensure that the
Irrevocable Revolving letter of Credit shall be renewed not later than forty-five (45) days prior to its expiry, annually.

 

11.4.1.6             All costs relating to opening and
maintenance of the Letter of Credit shall be borne by the Procurer.

 

11.4.1.7             Where necessary, the Irrevocable
Revolving Letter of Credit may also be substituted by an unconditional and irrevocable bank guarantee or an equivalent financial
instrument as mutually agreed by the Procurer and the Seller.

 

		11.5	Disputed Bill

 

11.5.1             If a Party does not dispute a Weekly
Bill, Provisional Bill or a Supplementary Bill raised by the other Party within thirty (30) days of receiving it, such bill shall
be taken as conclusive.

 

11.5.2             If a Party disputes the amount payable
under a Weekly Bill, Provisional Bill or a Supplementary Bill, as the case may be, that Party shall, within seven (7) days of receiving
such bill, issue a notice (the “Bill Dispute Notice”) to the invoicing Party setting out:

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	29

     

    

 

Power Purchase Agreement (PPA)

 

		  i.	the
details of the disputed amount;

		 ii.	its estimate of what the correct amount should be;
and

		iii.	all written material in support of its claim.

 

11.5.3             If
the invoicing Party agrees to the claim raised in the Bill Dispute Notice issued pursuant to clause 11.5.2, the invoicing
Party shall levies such bill within seven (7) days of receiving such notice and if the disputing Party has already made the
excess payment, refund to the disputing Party such excess amount within fifteen (15) days of receiving such notice. In such a
case excess amount shall be refunded along with interest at the same rate as Late Payment Surcharge which shall be applied
from the date on which such excess payment was made to the invoicing Party and up to and including the date on which such
payment has been received.

 

11.5.4             If the invoicing Party does not agree
to the claim raised in the Bill Dispute Notice issued pursuant to clause 11.5.2, it shall, within fifteen (15) days of receiving
the Bill Dispute Notice, furnish a notice to the disputing Party providing:

 

		  i.	reasons for its disagreement;

		 ii.	its estimate of what the correct amount should be;
and

		iii.	all written material in support of its counter-claim.

 

11.5.5             Upon receipt of notice of disagreement
to the Bill Dispute Notice under clause 11.5.4, authorized representative(s) or a director of the board of directors/member of
board of each Party shall meet and make best endeavours to amicably resolve such dispute within fifteen (15) days of receiving
such notice of disagreement to the Bill Dispute Notice.

 

11.5.6             If the Parties do not amicably resolve
the Dispute within fifteen (15) days of receipt of notice of disagreement to the Bill Dispute Notice pursuant to clause 11.5.4
the matter shall be referred to Dispute Resolution in accordance with clause 17.

 

11.5.7             In case of Disputed Bills, it shall
be open to the aggrieved party to approach the Appropriate Commission for Dispute Resolution in accordance with clause 17 and also
for interim orders protecting its interest including for orders for interim payment pending Dispute Resolution and the Parties
shall be bound by the decision of the Appropriate Commission, including in regard to interest or Late Payment Surcharge, if any
directed to be paid by the Appropriate Commission.

 

11.5.8             If a Dispute regarding a Weekly Bill,
Provisional Bill or a Supplementary Bill is settled pursuant to clause 11.5.5 or by Dispute resolution mechanism provided in this
Agreement in favour of the Party that issues a Bill Dispute Notice, the other Party shall refund the amount, if any incorrectly
charged and collected from the disputing Party or pay as required, within five (5) days of the Dispute either being amicably resolved
by the Parties pursuant to clause 11.6.5 or settled by Dispute resolution mechanism along with interest at the same rate as Late
Payment Surcharge from the date on which such payment had been made to the invoicing Party or the date on which such payment was
originally due, as may be applicable.

 

		11.6	Quarterly and Annual Reconciliation

 

Parties acknowledge that all payments made
against Weekly Bills, Provisional Bill and Supplementary Bills shall be subject to quarterly reconciliation at the beginning of
the following quarter of each Contract Year and annual reconciliation at the end of each Contract Year to take into account REA,
Tariff Adjustment Payments, Tariff Rebate Payments, Late Payment Surcharge, or any other reasonable circumstance provided under
this Agreement. The Parties, therefore, agree that as soon as all such data in respect of any quarter of a Contract Year or a full
Contract Year as the case may be has been finally verified and adjusted, the Seller and Procurer shall jointly sign such reconciliation
statement. Within fifteen (15) days of signing of a reconciliation statement, the Seller or Procurer, as the case may be, shall
raise a Supplementary Bill for the Tariff Adjustment Payments for the relevant quarter/ Contract Year and shall make payment of
such Supplementary Bill for the Tariff Adjustment Payments for the relevant quarter/Contract Year. Late Payment Surcharge shall
be payable in such case from the date on which such payment had been made to the invoicing Party or the date on which any payment
was originally due, as may be applicable. Any dispute with regard to the above reconciliation shall be dealt with in accordance
with the provisions of Article 17.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	30

     

    

 

Power Purchase Agreement (PPA)

 

		11.7	Payment of Supplementary Bill

 

11.7.1             Either
Party may raise a bill on the other Party (“Supplementary Bill”) for payment on account
of:

 

		i.	Adjustments
required by the Regional Energy Account (if applicable);

 

		ii.	Tariff
Payment for change in parameters, pursuant to provisions in Schedules VI and X; or and such Bill shall be paid by the other Party.

 

11.7.2             Procurer
shall remit all amounts due under a Supplementary Bill raised by the Seller to the Seller's Designated Account by the Due Date
and notify the Seller of such remittance on the same day. Similarly, the Seller shall pay all amounts due under a Supplementary
Bill raised by Procurer by the Due Date to the Procurer's designated bank account and notify the Procurer of such payment
on the same day.

 

11.7.3             In
the event of delay in payment of a Supplementary Bill by either Party beyond its Due Date, a Late Payment Surcharge shall be payable
at the same terms applicable to the Weekly Bill in clause 11.3.4.

 

		11.8	Payment for Startup Power

 

The Seller shall be liable to pay
for the power and energy consumed for start-up of the Project and commissioning, to the distribution Licensee(s) in whose area
the Project is located or such other entity from whom such power/energy is sourced, at the then prevalent rates payable by such
industrial consumers.

 

		11.9	The copy of all notices/offers

 

The copy of all notices/offers which are required
to be sent as per the provisions of this clause 11 shall be sent by either Party, simultaneously to all Parties.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	31

     

    

 

Power Purchase Agreement (PPA)

 

		12.	ARTICLE 12: FORCE MAJEURE

 

12.1             Definitions 

 

In this Article 12, the following terms shall have the following
meanings:

 

12.2             Affected
Party

 

An affected Party means the Procurer or the Seller whose performance
has been affected by an event of Force Majeure.

 

An event of Force Majeure affecting the
CTU/STU or any other agent of Procurer, which has affected the Interconnection Facilities, shall be deemed to be an event of Force
Majeure affecting Procurer.

 

Any event of Force Majeure affecting the performance
of the Seller's contractors shall be deemed to be an event of Force Majeure affecting Seller only if the Force Majeure event is
affecting and resulting in:

 

		a)	late delivery of plant, machinery, equipment, materials,
spare parts, Fuel, water or consumables for the Project; or

 

		b)	a delay in the performance of any of the Seller's contractors.

 

Similarly, any event of Force Majeure affecting
the performance of the Procurer's contractor for the setting up or operating Interconnection Facilities shall be deemed to be an
event of Force Majeure affecting Procurer only if the Force Majeure event is resulting in a delay in the Performance of Procurer's
contractors.

 

12.3             Force
Majeure

 

A “Force Majeure” means
any event or circumstance or combination of events and circumstances including those stated below that wholly or partly prevents
or unavoidably delays an Affected Party in the performance of its obligations under this Agreement, but only if and to the extent
that such events or circumstances are not within the reasonable control, directly or indirectly, of the Affected Party and could
not have been avoided if the Affected Party had taken reasonable care or complied with Prudent Utility Practices:

 

		  i.	Natural
Force Majeure Events:

 

Act of God, including, but not limited to lightning,
drought, fire and explosion (to the extent originating from a source external to the Site), earthquake, volcanic eruption, landslide,
flood, cyclone, typhoon, tornado, or exceptionally adverse weather conditions:

 

		 ii.	Non - Natural Force Majeure Events:

 

		1.	Direct Non - Natural Force Majeure Events:

 

		a)	Nationalization or compulsory acquisition by any Governmental
Instrumentality of any material assets or rights of the Seller or the Seller's contractors; or

 

		b)	the unlawful, unreasonable or discriminatory relocation
of, or refusal to renew, any Consent required by the Seller or any of the Seller's contractors to perform their obligations under
the Project Documents or any unlawful, unreasonable or discriminatory refusal to grant any other consent required for the development/
operation of the Project. Provided that an appropriate court of law declares the revocation or refusal to be unlawful, unreasonable
and discriminatory and strikes the same down.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	32

     

    

 

Power Purchase Agreement (PPA)

 

		c)	any
other unlawful, unreasonable or discriminatory action on the part of a Government Instrumentality which is directed against the
Project. Provided that an appropriate court of law declares the revocation or refusal to be unlawful, unreasonable and discriminatory
and strikes the same down.

 

		2.	Indirect
Non - Natural Force Majeure Events

 

		a)	any
act of war (whether declared or undeclared), invasion, armed conflict or act of foreign enemy, blockade, embargo, revolution,
riot, insurrection, terrorist or military action); or

 

		b)	Radioactive contamination or ionizing radiation originating
from a source in the country or resulting from another Indirect Non Natural Force Majeure Event excluding circumstances where
the source or cause of contamination or radiation is brought or has been brought into or near the site by the Affected Party or
those employed or engaged by the Affected Party.

 

		c)	Labor disturbances & strikes having a nationwide
impact in the country.

 

12.4             Force
Majeure Exclusions

 

Force Majeure shall not include (i) any event
or circumstance which is within the reasonable control of the Parties and (ii) the following conditions, except to the extent that
they are consequences of an event of Force Majeure:

 

		a)	Unavailability, late delivery, or changes in cost
of the plant, machinery, equipment, materials, spare parts, Fuel or consumables for the Project;

 

		b)	Delay in the performance of any contractor, sub-contractors
or their agents excluding the conditions as mentioned in clause 12.2;

 

		c)	Non-performance resulting from normal wear and tear
typically experienced in power generation materials and equipment;

 

		d)	Strikes or labour disturbance at the facilities of
the Affected Party;

 

		e)	Insufficiency of finances or funds or the agreement
becoming onerous to perform;

 

		f)	Non-performance caused by, or connected with, the
Affected Party's:

 

		  i.	Negligent or intentional acts, errors or omissions;

 

		 ii.	Failure to comply with Autonomous Island of Grande
Comore, Union of the Comoros Law; or

 

		iii.	Breach of, or default under this Agreement or any Project
Documents.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	33

     

    

 

Power Purchase Agreement (PPA)

 

12.5             Notification
of Force Majeure Event

 

The Affected Party shall give notice to
the other Party of any event of Force Majeure as soon as reasonably practicable, but not later than seven (7) days after the
date on which such Party knew or should reasonably have known of the commencement of the event of Force Majeure. If an event
of Force Majeure results in a breakdown of communications rendering it unreasonable to give notice within the applicable time
limit specified herein, then the Party claiming Force Majeure shall give such notice as soon as reasonably practicable after
reinstatement of communications, but not later than one (1) day after such reinstatement, provided that such notice shall be
a pre-condition to the Seller's entitlement to claim relief under this Agreement. Such notice shall include full particulars
of the event of Force Majeure, its effects on the Party claiming relief and the remedial measures proposed. The Affected
Party shall give the other Party regular (and not less than monthly) reports on the progress of those remedial measures and
such other information as the other Party may reasonably request about the situation.

 

The Affected Party shall give notice to the
other Party of (i) the cessation of the relevant event of Force Majeure; and (ii) the cessation of the effects of such event of
Force Majeure on the performance of its rights or obligations under this Agreement, as soon as practicable after becoming aware
of each of these cessations.

 

12.6             Duty
to perform and duty to Mitigate

 

To the extent not prevented by a Force Majeure
event pursuant to clause 12.3, the Affected Party shall continue to perform its obligations pursuant to this Agreement. The Affected
Party shall use its reasonable efforts to mitigate the effect of any event of Force Majeure as soon as practicable.

 

12.7            Available Relief for a Force Majeure Event

 

Subject to this Article 12:

 

		a)	no Party shall be in breach of its obligations pursuant
to this Agreement to the extent that the performance of its obligations was prevented, hindered or delayed due to a Force Majeure
Event;

 

		b)	every Party shall be entitled to claim relief in relation
to a Force Majeure Event in regard to its obligations, and

 

		c)	in case of a Non-Natural Force Indirect Majeure Event
affecting the Procurer which adversely affects the performance obligations of the Seller under this Agreement, the following provisions
shall apply.

 

		 i.	if the average Availability of the Power Station is
reduced below sixty (60) percent for over two (2) consecutive months or for any nonconsecutive period of four (4) months both
within any continuous period of sixty (60) months, then, with effect from the end of that period and for so long as the daily
average availability of the Power Station continues to be reduced below sixty (60) percent, the Procurer shall make payments for
Debt Service for the duration of force majeure.

 

		ii.	For so long as the Seller is claiming relief due to
any Natural Force Majeure Event affecting the Procurer under this Agreement, the Procurer may from time to time on one (1) days
notice inspect the Project and the Seller shall provide Procurer's personnel with access to the Project to carry out such inspections,
subject to the Procurer's personnel complying with all reasonable safety precautions and standards.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	34

     

    

 

Power Purchase Agreement (PPA)

 

		d)	In the case of an unnatural event of direct force majeure
preventing the Seller from his obligations:

 

		 i.	The Procurer will pay all incurred expenses, operational
costs, bills and invoices, even though the Seller does not procure any electricity for resale to the Procurer (Full responsibility
of Procurer). In this case, the Seller may terminate the contract, as a breach of contract on behalf of the Procurer, with prejudice,
and the Procurer will pay all costs and Penalties to Seller, whereby the costs and penalties are the same as referenced in the
Municipal Solid Waste Concession Agreement.

 

12.8            Additional Compensation and Procurer's
Subrogation

 

If the Seller is entitled, whether actually
or contingently, to be compensated by any person/entity (Insurance) other than the Procurer as a result of the occurrence of a
Non Natural Indirect Force Majeure Event affecting the Procurer for which it has received compensation from the Procurer pursuant
to this Article 12.7 (c) i, the Procurer shall be fully subrogated to the Seller's rights against that person to the extent of
the compensation paid by the Procurer to the Seller. Provided that in case the Seller has actually received compensation from any
person other than the Procurer as well as the Procurer as a result of the occurrence of a Non-Natural Indirect Force Majeure Event
affecting the Procurer, then the Seller shall forthwith refund the compensation received by it (without any accrued interest) from
the Procurer but only to the maximum extent of the compensation received by the Seller from any person other than the Procurer.

 

		13.	ARTICLE 13: EVENTS OF DEFAULT & TERMINATION

 

13.1             Seller
Event of Default

 

The occurrence and continuation of any of the
following events, unless any such event occurs as a result of a Force Majeure Event or a breach by Procurer of its obligations
under this Agreement, shall constitute a Seller Event of Default:

 

		  i.	the
failure to Commission the Power Station by the date falling twelve (12) Months after its Scheduled Commercial Operation Date,
or

 

		 ii.	after the commencement of construction of the Project,
the abandonment by the Seller or the Seller's Construction Contractors of the construction of the Project for a continuous period
of two (2) Months and such default is not rectified within thirty (30) days from the receipt of first notice from the Procurer
in this regard, or

 

		iii.	if at any time
following the Power Station being Commissioned and during its retest, as per Article 8, the Tested Capacity is less than eighty
(80) percent of its Contracted Capacity, as existing on the Effective Date or in case the Seller has exercised the option under
clause 3.1.1 the Contracted Capacity so finalized, and such Tested Capacity remains below eighty (80) percent even for a period
of three (3) Months thereafter; or

 

		iv.	after Commercial
Operation Date of the Power Station, the Seller fails to achieve Average Availability of sixty five percent (65%), for a period
of twelve (12) consecutive Months or within a non-consecutive period of twelve (12) Months within any continuous aggregate period
of thirty-six (36) Months, or

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	35

     

    

 

Power Purchase Agreement (PPA)

 

		  v.	if the Seller:

 

		a)	negates any of its rights and/or obligations under
this agreement, in violation of this Agreement; or

 

		 vi.	if (a) the Seller becomes voluntarily or involuntarily
the subject of any bankruptcy or insolvency or winding up proceedings and such proceedings remain uncontested for a period of
thirty (30) days, or (b) any winding up or bankruptcy or insolvency order is passed against the Seller, or (c) the Seller goes
into liquidation or dissolution or has a receiver or any similar officer appointed over all or substantially all of its assets
or official liquidator is appointed to manage its affairs, pursuant to Law, provided that a dissolution or liquidation of the
Seller will not be an Event of Default if such dissolution or liquidation is for the purpose of
a merger, consolidation or reorganization and where the resulting company continues to meet the financial and technical
requirements till COD of the Power Station, and retains creditworthiness similar to the Seller and expressly assumes all obligations
of the Seller under this Agreement and is in a position to perform them; or

 

		vii.	the Seller repudiates this Agreement and does not
rectify such breach even within a period of sixty (60) days from a notice from the Procurer in this regard; or

 

		viii.	the Seller fails to complete/fulfill the activities/conditions
specified in clause 3.1.2, beyond a period of 8 Months from the specified period in clause 3.1.2 and the right of termination
under clause 3.3.2 is invoked by the Procurer; or

 

		  ix.	Occurrence of any other event which is specified in
this Agreement to be a material breach/default of the Seller.

 

13.2             Procurer Event of Default 

 

The occurrence and the continuation of any
of the following events, unless any such event occurs as a result of a Force Majeure Event (natural and/or non-natural indirect)
or a breach by the Seller of its obligations under this Agreement, shall constitute the Event of Default on the part of defaulting
Procurer:

 

		  i.	a
defaulting Procurer fails to pay (with respect to a Weekly Bill or a Supplementary Bill) an amount exceeding fifteen (15) percent
of the undisputed part of the Weekly / Supplementary Bill for a period of ninety (90) days after the Due Date and the Seller is
unable to recover the amount outstanding to the Seller through the Irrevocable Revolving Letter of Credit; or

 

		 ii.	the defaulting Procurer repudiates this Agreement
and does not rectify such breach even within a period of thirty (30) days from a notice from the Seller in this regard; or

 

		iii.	any representation and warranties made by the Procurer
of this Agreement (Schedule VII) being found to be untrue or inaccurate. Provided however, prior to considering any event specified
under this sub-article to be an Event of Default, the Seller shall give a notice to the Procurer in writing of thirty (30) days.
If the Procurer responds to the aforesaid notice within the thirty (30) days of reception, the Procurer will be granted thirty
days to remedy same. If the Procurer does not respond, the Seller will send a written notice to terminate the contract within
seven (7) days, thereafter for Event of Default and Termination, with prejudice; or

 

		 iv.	occurrence of any other event which is specified in
this Agreement to be a material breach/default of the Seller.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	36

     

    

 

Power Purchase Agreement (PPA)

 

13.3
Procedure for cases of Seller Event of Default

 

13.3.1             Upon the occurrence and continuation
of any Seller Event of Default under clause 13.1, the Procurer shall have the right to deliver to the Seller a Procurer Preliminary
Default Notice, which shall specify in reasonable detail, the circumstances giving rise to the issue of such notice.

 

13.3.2             Following the issue of Procurer’s
Preliminary thirty (30) day Default Notice, the Seller shall be given thirty (30) days or such longer period as the Parties may
agree, after Seller’s written response within the thirty (30) days of the Procurer’s notice, for the remedy of same.

 

13.3.3             During
the Consultation Period, the Parties shall, save as otherwise provided in this Agreement, continue to perform their respective
obligations under this Agreement.

 

13.3.4             Within a period of seven (7) days
following the expiry of the sixty (60) day notice and response period unless the Parties shall have otherwise agreed to the contrary
or the Seller Event of Default giving rise to the Consultation Period shall have been remedied, the Lenders may exercise or the
Procurer may require the Lenders to exercise their substitution rights and other rights provided to them, if any, under Financing
Agreements and the Procurer would have no objection to the Lenders exercising their rights if it is in consonance with provisions
of Schedule IX.

 

13.4
Termination for Procurer Events of Default

 

13.4.1             Upon the occurrence and continuation
of any Procurer Event of Default under clause 13.2, the Seller shall have the right to deliver to the Procurer a Seller Preliminary
Default Notice, which shall specify in reasonable detail, the circumstances giving rise to the issue of such notice.

 

13.4.2             Following the issue of Seller’s
Preliminary thirty (30) day Default Notice, the Procurer shall be given thirty (30) days or such longer period as the Parties may
agree, after Procurer’s written response within the thirty (30) days of the Seller’s notice, for the remedy of same.

 

13.4.3             During the Consultation Period, the
Parties shall continue to perform their respective obligations under this Agreement.

 

13.4.4             After a period of seven (7) days
following the expiry of the Consultation Period and unless the Parties shall have otherwise agreed to the contrary or the Procurer
Event of Default shall have been remedied, the Procurer will continue to respect all of his obligations until the end of the term
of the contract and the renewal option. If, after the sixty (60) days, the Procurer did not remedy the default, the Seller will
send a seven (7) day notice to deem this contract null and void (Termination of Contract). The Procurer will be totally responsible
for penalties, damages, interest, and other related prejudices.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	37

     

    

 

Power Purchase Agreement (PPA)

 

		14.	ARTICLE 14: LIMITATION OF LIABILITY

 

Except as expressly provided
in this Agreement, neither the Seller nor Procurer nor their respective officers, directors, agents, employees or Affiliates
(or their officers, directors, agents or employees), shall be liable or responsible to the other Party or its Affiliates,
officers, directors, agents, employees, successors or permitted assigns (or their respective insurers) for incidental,
indirect or consequential damages, connected with or resulting from performance or non-performance of this Agreement, or
anything done in connection herewith, including claims in the nature of lost revenues, income or profits (other than payments
expressly required and properly due under this Agreement), any increased expense of, reduction in or loss of power generation
production or equipment used therefore, irrespective of whether such claims are based upon breach of warranty, tort
(including negligence, whether of the Procurers, the Seller or others), strict
liability, contract, breach of statutory duty, operation of law or otherwise. Procurer shall have no recourse against any
officer, director or shareholder of the Seller or any Affiliate of the Seller or any of its officers, directors or
shareholders for such claims excluded under this Article.

 

		15.	ARTICLE 15: ASSIGNMENTS AND CHARGES

 

		15.1	Assignments

 

This Agreement shall be binding
upon, and inure to the benefit of the Parties and their respective successors and permitted assigns. The Seller can assign (sell/transfer)
this agreement to any affiliate, holding, third party or Lenders by simply notifying Procurer of same. This Agreement and the
other Project Documents shall continue to remain valid and binding on such successor of assignment (sell/transfer).

 

For further clarity and notwithstanding anything contained above
in this clause, the Seller shall not require any prior approval of the Procurer for assigning its rights and obligations under
this Agreement.

 

Permitted Charges

 

15.2.1             Notwithstanding anything contained
in clause 15.1, the Seller shall not require any prior approval of Procurer (First Party) for creating any encumbrance, right,
title, or interest over all or part of the receivables, Payment Mechanism or the Project Facilities and/or the other assets of
the Project and/or the Project Documents in favour of the Lenders or the Lender's Representative on their behalf, only for the
purposes of carrying out the obligations under this Agreement, as security for:

 

		a)	amounts payable under the Financing Agreements; and

 

		b)	any other amounts agreed by the Parties,

 

15.2.2             clause 15.1 does not apply to:

 

		a)	liens arising by operation of law (or by an agreement
evidencing the same) in the ordinary course of the Seller carrying out the Project;

 

		b)	pledges of goods, the related documents of title and
/ or other related documents, arising or created in the ordinary course of the Seller carrying out the Project; or

 

		c)	security arising out of retention of title provisions
in relation to goods acquired in the ordinary course of the Seller carrying out the Project.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	38

     

    

 

Power Purchase Agreement (PPA)

 

		16.	ARTICLE 16: GOVERNING LAW AND DISPUTE RESOLUTION
(ARBITRATION)

 

16.1 Governing Law

 

This Agreement shall be governed by and construed in accordance
with the Laws of Canada.

 

16.2 Amicable Settlement

 

16.2.1             Either Party is entitled to raise
any claim, dispute or difference of whatever nature arising under, out of or in connection with this Agreement including its existence
or validity or termination (collectively “Dispute”) by giving a written notice to the other Party, which shall
contain:

 

		  i.	a description of the Dispute;

 

		 ii.	the grounds for such Dispute; and

 

		iii.	all written material in support of its claim.

 

16.2.2             The
other Party shall, within thirty (30) days of issue of dispute notice issued under clause 16.2.1, furnish:

 

		  i.	counter-claim and defenses, if any, regarding the
Dispute; and

 

		 ii.	all written material in support of its defenses and
counter-claim.

 

16.2.3             Within thirty (30) days of issue
of notice by any Party pursuant to clause 16.2.1 or clause 16.2.2, both the Parties to the Dispute shall meet to settle such Dispute
amicably. If the Parties fail to resolve the Dispute amicably within thirty (30) days of receipt of the notice referred to in the
preceding sentence, the Dispute shall be referred to Dispute Resolution in accordance with clause 16.3.

 

16.3 Dispute Resolution

 

16.3.1             For all disputes that arise, the Disputes
will be resolved by arbitration, and will respect the rules, regulations and procedures thereto. The Disputes shall be resolved
by arbitration under the Canadian Arbitration and Conciliation Act and its by-laws. Herein under is the procedure to be followed:

 

		  i.	The Arbitration tribunal shall consist of three (3)
arbitrators to be appointed in accordance with the Canadian Council of Arbitration Rules. Each of the parties will select an arbitrator
and the two (2) arbitrators will select the third (3rd) arbitrator.

 

		  ii.	The place of arbitration shall be Canada. The language
of the arbitration shall be English, with official translation services in French.

 

		iii.	The arbitration tribunal's award shall be substantiated
in writing. The arbitration tribunal shall also decide on the costs of the arbitration proceedings and the allocation thereof.

 

		iv.	The arbitration decision (award) shall be approved
as final and enforceable in any court having jurisdiction in the country of the First Party, acknowledging and approving same,
subject to the applicable laws thereto.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	39

     

    

 

Power Purchase Agreement (PPA)

 

16.4 Parties to Perform Obligations

 

Notwithstanding the existence of any Dispute
and difference referred to the Appropriate Commission or the arbitral tribunal as provided in clause 16.3 and save as the Appropriate
Commission or the arbitral tribunal may otherwise direct by a final or interim order, the Parties hereto shall continue to perform
their respective obligations (which are not in dispute) under this Agreement.

 

17. ARTICLE 17: MISCELLANEOUS PROVISIONS

 

17.1 Amendment

 

This Agreement may only be amended or supplemented by a written
agreement between the Parties and after duly obtaining the approval of the Appropriate Commission, where necessary.

 

17.2 Third Party Beneficiaries

 

This Agreement is solely for the benefit of
the Parties and their respective successors and permitted assigns and shall not be construed as creating any duty, standard of
care or any liability to, any person not a party to this Agreement.

 

17.3 No Waiver

 

A valid waiver by a Party shall be in writing
and executed by an authorized representative of that Party. Neither the failure by any Party to insist on the performance of the
terms, conditions, and provisions of this Agreement nor time or other indulgence granted by any Party to the other Parties shall
act as a waiver of such breach or acceptance of any variation or the relinquishment of any such right or any other right under
this Agreement, which shall remain in full force and effect.

 

17.4 Entirety

 

17.4.1             This Agreement and the Schedules
are intended by the Parties as the final expression of their agreement and are intended also as a complete and exclusive statement
of the terms of their agreement.

 

17.4.2             Except as provided in this Agreement,
all prior written or oral understandings, offers or other communications of every kind pertaining to this Agreement by and between
the Procurer and the Seller shall stand superseded and abrogated.

 

17.5 Confidentiality 

 

The Parties undertake to hold in confidence
this Agreement and Project Documents and not to disclose the terms and conditions of the transaction contemplated hereby to third
parties (without the prior written consent of the other Parties), except:

 

		a)	to their professional advisors;

 

		b)	to their officers, contractors, employees, agents or
representatives, financiers, who need to have access to such information for the proper performance of their activities; or

 

		c)	disclosures required under Law.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	40

     

    

 

Power Purchase Agreement (PPA)

 

17.6 Affirmation

 

The Seller and Procurer, each affirm that neither
it, nor its respective directors, employees or agents has paid or undertaken to pay or shall in the future pay any unlawful commission,
pay-off or kick-back.

 

17.7 Severability

 

The invalidity or enforceability, for any reason,
of any part of this Agreement shall not prejudice or affect the validity or enforceability of the remainder of this Agreement,
unless the part held invalid or unenforceable is fundamental to this Agreement.

 

17.8 No Partnership

 

None of the provisions of this Agreement shall constitute a partnership
or agency or any such similar relationship between the Seller and Procurer.

 

17.9 Survival

 

Notwithstanding anything to the contrary herein,
the provisions of this Agreement, including clause 3.3.2, clause 10.2 (Application of Insurance Proceeds), Article 12 (Force Majeure),
Article 13 (Events of Default and Termination), Article 16 including clause 16.3 (Governing Law and Dispute Resolution), Article
17 (Miscellaneous), and other Articles and Schedules of this Agreement which expressly or by their nature survive the term (and/or
the exercised renewal option) of this Agreement shall continue and survive any expiry or termination of this Agreement.

 

17.10             Counterparts

 

This Agreement may be executed in six (6) or
more counterparts, each of which shall be deemed an original and all of which collectively shall be deemed one and the same instrument.

 

17.11             Notices

 

All notices to be given under this Agreement shall be in writing
and in the English Language.

 

All notices must be delivered personally, by
registered post or any method duly acknowledged or facsimile to the addresses below:

 

Seller:

 

BioCrude Technologies, Inc. 

1255 Phillips Square, Suite 605 

Montreal, Québec, Canada H3B 3G5

 

(Attn: Mr. John MOUKAS; Chairman/CEO)

 

Tel: (877) 878-1268 

Fax: (877) 778-1568 

Email: jmoukas@biocrudetech.com

Website: http://www.biocrudetech.com

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	41

     

    

 

Power Purchase Agreement (PPA)

 

Procurer

 

(Office of Proxy):

 

Gouvernorat de l’Île
Autonome de la Grande Comore

Route de Moroni- Itsandra

Moroni, Autonomous Island of Grande Comore, Union of the
Comoros

 

(Attn: The Honourable HASSANI Hamadi, Governor and/or

Mr. Mohamed Abdou MLANAO, Commissaire à l’Environnement,
à l’Urbanisme, au

Développement Durable et à l’Énergie, à l’Emploi, à
l’Entreprenariat et à la Solidarité)

 

Tel: +269 773 13 64; +269 773 84 77; +269 764 44 77

Fax:

Email: sgg.ngazidja@gmail.com

Website: http://www.gouvernorat-ngazidja.com

 

All
notices or communications given by facsimile shall be confirmed by sending a copy of the same via post office in an envelope properly
addressed to the appropriate Party for delivery by registered mail. All Notices shall
be deemed validly delivered upon receipt evidenced by an acknowledgement of the recipient, unless the Party delivering the notice
can prove in case of delivery through the registered post that the recipient refused to acknowledge the receipt of the notice
despite efforts of the post authorities.

 

Any Party may by notice of at least fifteen
(15) days to the other Parties change the address and / or addresses to which such notices and communications to it are to be delivered
or mailed.

 

17.12             Language

 

The language of this Agreement and all written
communication between the Parties relating to this Agreement shall be in English and French.

 

17.13             Breach
of Obligations

 

The Parties acknowledge that a breach of any
of the obligations contained herein would result in damages. The Parties further acknowledge that the amount of the liquidated
damages or the method of calculating the liquidated damages specified in this Agreement is a reasonable estimate of the damages
that may be suffered by the non-defaulting party in each case specified under this Agreement, but can be different to reflect same.

 

17.14             Commercial
Acts

 

The Procurer and Seller unconditionally and irrevocably agree that
the execution, delivery and performance by each of them of this Agreement and those agreements included in the Collateral Arrangement
to which it is a Party constitute private and commercial acts rather than public or governmental acts.

 

The Procurer hereby unconditionally and irrevocably:

 

		  i.	waives
any right of immunity, sovereign or otherwise and

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	42

     

    

 

Power Purchase Agreement (PPA)

 

		 ii.	agrees
that should any proceedings be brought against it or its assets in relation to this Agreement or any transaction contemplated
by this Agreement no immunity, sovereign or otherwise, from such proceedings, execution, attachment or other legal process shall
be claimed by or in behalf of itself or with respect to any of its assets.

 

17.15             Restriction
of Shareholders/Owners Liability

 

Parties expressly agree and acknowledge that
none of the shareholders of the Parties hereto shall be liable to the other Parties for any of the contractual obligations of the
concerned party under this Agreement. Further, the financial liabilities of the shareholder/s of each Party to this Agreement,
in such Party, shall be restricted to the extent provided by law.

 

17.16             General Continuing Guaranty

 

17.17.1          Guaranty of Obligations

 

Guarantor unconditionally, absolutely and irrevocably
guarantees and promises to pay to Seller, on order or demand, in lawful money of American (US) dollars, any and all indebtedness
and obligations of Procurer (First Party) to Seller and the payment to Seller of all sums which may be presently due and owing
to Seller from Procurer under this Agreement, and by extension the renewal option. The terms indebtedness and obligations are (hereinafter
collectively referred to as the Obligations) used herein in their most comprehensive sense and include any and all advances, debts,
obligations and liabilities of Procurer, heretofore, now, or hereafter made, incurred or created, whether voluntarily or involuntarily,
and however arising whether due or not due, absolute or contingent, liquidated or unliquidated, determined or undetermined, whether
Procurer may be liable individually or jointly with others, whether recovery upon such indebtedness may be or hereafter becomes
barred by any statute of limitations or whether such indebtedness may be or hereafter becomes otherwise unenforceable, and includes
Seller’s prompt, full and faithful performance regarding the execution of these presences. The Guarantor will allow the Seller
to seize and sell its assets (including marketable commodities) up to amount of the monetized default (monies owed), in the case
that the Guarantor does not have the capacity to execute payment of its defaulted obligations.

 

17.17.2          Continuing
Guaranty

 

This General Continuing Guaranty is a continuing
guaranty which shall remain effective until this Guaranty has been expressly terminated and relates to any obligations including
those which arise under successive transactions which shall either continue the Obligations from time to time or renew them after
they have been satisfied. Any such termination shall be applicable only after written notice to Seller, and only to transactions
having their inception prior to such date. No termination shall be effective until such time as Procurer (First Party) is no longer
committed or otherwise obligated to make any payment to Seller. In the absence of any termination of this Guaranty, Guarantor agrees
that nothing shall discharge or satisfy its obligations created hereunder except for the regular full payments till the termination
of these presences.

 

17.17.3          Rights
are Independent

 

Guarantor agrees that it is directly and primarily
liable to Seller, that the obligations hereunder are independent of the obligations of Procurer and that a separate action or actions
may be brought and prosecuted against Guarantor, whether action is brought against Procurer or whether Seller is joined in any
such action or actions. Guarantor agrees that any releases which may be given by Procurer to Seller or any other guarantor or endorser
shall not release it from this Guaranty.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	43

     

    

 

Power Purchase Agreement (PPA)

 

17.17.4             Default

 

In the event that any bankruptcy, insolvency,
receivership or similar proceeding is instituted by or against Guarantor and/or the Procurer or in the event that either the Guarantor
or Seller become insolvent, make an assignment for the benefit of creditors or attempt to effect a composition with creditors,
or if there be any default under the Agreement (whether declared or not), then, at Procurer election, without notice or demand,
the Obligations of Guarantor created hereunder shall become due, payable and enforceable against Guarantor whether or not the Obligations
are then due and payable.

 

17.17.5             Indemnification

 

Guarantor agrees to indemnify Seller
and hold Seller harmless against all obligations, demands and liabilities, by whomsoever asserted and against all losses in any
way suffered, incurred or paid by Procurer as a result of or in any way arising out of, following or consequential to transactions
with Procurer whether under the Agreement, or otherwise, and also agrees that this Guaranty shall not be impaired by any modification,
supplement, extension or amendment of any contract or agreement to which Procurer and Seller may hereafter agree, nor by any modification,
release or other alteration of any of the Obligations hereby guaranteed or of any security therefore, nor by any agreements or
arrangements whatever with Procurer or anyone else.

 

17.17.6             Waiver
of Defenses 

 

Guarantor hereby waives any right to assert
against Seller as a defense, counterclaim, setoff on cross claim, any defense (legal or equitable), setoff, counterclaim and claim
which Guarantor may now or at any time hereafter have against Seller and any other party liable to Procurer in any way or manner.

 

Guarantor hereby waives all defenses, counterclaims
and offsets of any kind or nature, arising directly or indirectly from the present or future lack of perfection, sufficiency, validity
or enforceability of the agreements or any security interest thereunder.

 

Guarantor hereby waives any defense arising
by reason of any claim or defense based upon an election of remedies by Procurer, which, in any manner impairs, affects, reduces,
releases, destroys or extinguishes Guarantors subrogation rights, rights to proceed against Procurer for reimbursement, or any
other rights of the Guarantor or against any other person or security, including, but not limited to, any defense based upon an
election of remedies by Procurer under the provisions of applicable country law. Guarantor waives all presentments, demands for
performance, notices of nonperformance, protests, notices of protests, notice of dishonor, notices of default, notice of acceptance
of this Guaranty, and notices of the existence, creating or incurring of new or additional indebtedness, and all other notices
or formalities to which Guarantor may be entitled.

 

17.17.7             Waiver
of Jury Trial

 

Guarantor waives any right to a jury trial
in any action hereunder or arising out of Procurer transactions with Seller.

 

If a Dispute arises out of or in connection
with any claims regarding the current article, such Dispute shall be resolved by arbitration under the Canadian Arbitration and
Conciliation Act, and the Rules of the Canadian Council of Arbitration, in accordance with the process specified in article 1.60.1.
In the event of such Dispute remaining unresolved, any party to such Dispute may refer the matter to registrar under the Rules
of the Canadian Council of Arbitration.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	44

     

    

 

Power Purchase Agreement (PPA)

 

17.17.8             Waiver
of Rights of Subrogation

 

The Guarantor shall have no right of subrogation,
reimbursement, exoneration, contribution or any other rights that would result in the Guarantor being deemed a creditor of Procurer
under the Bankruptcy Code or any other law in that country or for any other purpose and the Guarantor hereby irrevocably waives
all such rights, the right to assert any such rights and any right to enforce any remedy which Guarantor may now or hereafter have
against Procurer and hereby irrevocably waives any benefit of and any right to participate in, any security now or hereafter held
by Procurer, whether any of the foregoing rights arise in equity, at law or by contract.

 

17.17.9             Financial
Condition of Procurer 

 

Guarantor is presently informed of the
financial condition of the Procurer and of all other circumstances which a diligent inquiry would reveal and which bear upon the
risk of nonpayment of the Obligations. Guarantor hereby covenants that it will continue to keep itself informed of Procurer financial
condition and of all other circumstances, which bear upon the risk of nonpayment. Absent a written request for such information
by the Guarantor to Procurer, Guarantor hereby waives its right, if any, to require, and Procurer is relieved of any obligation
or duty to disclose to Guarantor any information which Procurer may now or hereafter acquire concerning such condition or circumstances.

 

17.17.10             Termination

 

The Guarantor obligation under this Guaranty
shall continue for the duration of the term and renewal option, in full force and effect until Procurer Obligations are fully paid,
performed and discharged and Seller gives the Guarantor written notice of that fact. Procurer obligations shall not be considered
fully paid, performed and discharged unless and until all payments by Procurer to Seller are no longer subject to any right on
the part of any person whomsoever; including but not limited to Seller, or any trustee or receiver in bankruptcy, to set aside
such payments or seek to recoup the amount of such payments, or any part thereof. The foregoing shall include, by way of example
and not by way of limitation, all rights to recover preferences voidable under law in the country. In the event that any such payments
by Procurer to Seller are set aside after the making thereof, in whole or in part, or settled without litigation, to the extent
of such settlement, all of which is within Procurer discretion, Guarantor shall be liable for the full amount Procurer is required
to repay plus costs, interest, attorneys’ fees and any and all expenses which Seller paid or incurred in connection therewith.

 

17.17.11             Successors
and Assigns

 

This Guaranty shall be binding upon the successors
and assigns of the Guarantor and shall inure to the benefit of Seller successors and assigns.

 

17.17.12             Modifications

 

This Guaranty cannot be modified orally. No
modification of this Guaranty shall be effective for any purpose unless it is in writing and executed by an officer of Seller authorized
to do so. All prior agreements, understandings, representations and negotiations; if any, are merged into this Guaranty.

 

17.17.13             Joint
and Several

 

In all cases where the word Guarantor is used
in this Guaranty, it shall mean and apply equally to each and all of the individuals and/or entities, which have executed this
Guaranty. All of the obligations of the Guarantor hereunder shall be joint and several.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	45

     

    

 

 

 

    	46

     

    

  

 

    	47

     

    

 

 

 

    	48

     

    

 

Power Purchase Agreement (PPA)

 

SCHEDULE I

Names and Details of the Procurer

Procurer: LE GESTION DE L’EAU ET DE L’ÉLECTRICITÉ
AUX COMORES (MA-MWE)

 

OFFICE OF PROXY:

 

Gouvernorat de l’Île
Autonome de la Grande Comore

Route de Moroni- Itsandra

Moroni, Autonomous Island of Grande Comore, Union of the Comoros

 

(Attn: The Honourable HASSANI Hamadi, Governor and/or

Mr. Mohamed Abdou MLANAO, Commissaire à l’Environnement,
à

l’Urbanisme, au Développement Durable et à
l’Énergie, à l’Emploi, à

l’Entreprenariat et à la Solidarité)

 

Tel: +269 773 13 64; +269 773 84 77; +269 764 44 77

Fax:

Email: sgg.ngazidja@gmail.com

Website: http://www.gouvernorat-ngazidja.com

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	49

     

    

 

Power Purchase Agreement (PPA)

 

SCHEDULE I.A: SITE

 

Location: Moroni, Autonomous Island of Grande Comore, Union
of the Comoros

See Detailed Project Report for Details

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	50

     

    

 

Power Purchase Agreement (PPA)

 

SCHEDULE II: INITIAL CONSENTS

 

The Initial Consents (if applicable) required include:

 

The table below gives the name and status of all the Statutory
and Non-Statutory Clearances involved in this project.

 

	Statutory Clearances
	Authorization of Pollution Control	Commissariat à l’Environnement, à l’Urbanisme, au Développement Durable et à l’Énergie, à l’Emploi, à l’Entreprenariat et à la Solidarité
	Pollution Clearance from the Ministère de la Production, de l'Environnement, de l'Énergie, de l'Industrie et de l'Artisanat de l’Union des Comores and Consent to Establish and Operate Plant	Commissariat à l’Environnement, à l’Urbanisme, au Développement Durable et à l’Énergie, à l’Emploi, à l’Entreprenariat et à la Solidarité
	Civil Aviation Clearance for Stack Height	Commissariat à l’Environnement, à l’Urbanisme, au Développement Durable et à l’Énergie, à l’Emploi, à l’Entreprenariat et à la Solidarité
	Municipal board for treated sewage	Commissariat à l’Environnement, à l’Urbanisme, au Développement Durable et à l’Énergie, à l’Emploi, à l’Entreprenariat et à la Solidarité & le Gestion de l'Eau et de l'Électricité aux Comores (MA-MWE)
	Town & Country Planning Clearance	Commissariat à l’Environnement, à l’Urbanisme, au Développement Durable et à l’Énergie, à l’Emploi, à l’Entreprenariat et à la Solidarité
	Host Country Approval for CDM under Kyoto protocol	Commissariat à l’Environnement, à l’Urbanisme, au Développement Durable et à l’Énergie, à l’Emploi, à l’Entreprenariat et à la Solidarité
	Non-Statutory Clearances
	Construction power	le Gestion de l'Eau et de l'Électricité aux Comores (MA-MWE)
	Power Purchase Agreement (PPA)	Commissariat à l’Environnement, à l’Urbanisme, au Développement Durable et à l’Énergie, à l’Emploi, à l’Entreprenariat et à la Solidarité & le Gestion de l'Eau et de l'Électricité aux Comores (MA-MWE)
	Power evacuation arrangements	Commissariat à l’Environnement, à l’Urbanisme, au Développement Durable et à l’Énergie, à l’Emploi, à l’Entreprenariat et à la Solidarité & le Gestion de l'Eau et de l'Électricité aux Comores (MA-MWE)

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	51

     

    

 

Power Purchase Agreement (PPA)

 

SCHEDULE III: FUNCTIONAL SPECIFICATIONS

 

	No.	Description	 	Unit	Particulars
	 	 	 	 	 
	1.1 Grid Conditions at Interconnection Point	 	 
	 	 	 	 
	(i)	Voltage	: Nominal	kV	[      ]
	 	 	 	 	 
	 	 	  Variation	%	[      ]
	(ii)	Frequency	: Nominal	Hz	[      ]
	 	 	 	 	 
	 	 	  Variation	%	[      ]
	 	 	 	 	 
	(iii)	Combined Voltage and Frequency variation for Contracted Capacity	%	[      ]
	 	 	 	 
	(iv)	Power Factor	: Nominal	 	[      ]
	 	 	  Variation	 	[      ] to [      ]
	(v)	Basic Impulse Level (Peak)	 	kV	[      ]
	 	 	 	 	 
	1.2 Fault Levels:	 	 	 
	 	 	 	 
	(i) 3 Phase	  Maximum	kA	 [      ]
	 	 	 	 
	(ii) Clearance time	  Maximum	ms	 [      ]

 

1.3 Ramp Rates

 

All Units of the Power Station shall be capable of increasing or
decreasing their output (generation level) by not less than one percent (1%) per minute. Such capability shall be demonstrated
using the Unit Load of 50%.

 

1.4 Details about the Added Information

 

The information requested in this schedule, above, will be provided
by the Procurer within thirty (30) days after the execution hereof. In this case, this documented information will be added to
and form part of these presences.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	52

     

    

 

Power Purchase Agreement (PPA)

 

SCHEDULE IV: COMMISSIONING & TESTING

 

Performance Test

 

i.

 

		a)	The Performance Test shall be conducted under any and
all ambient conditions (temperature, humidity etc.) and any and all Fuel qualities that may exist during the time of the Performance
Test and no corrections in final gross and net output of the Unit will be allowed as a result of prevailing ambient conditions
or Fuel quality.

 

		b)	The
correction curves will only be used if the Grid System operation during the Performance Test exceeds electrical system limits.

 

		c)	The
Performance Test shall be deemed to have demonstrated the Actual Capacity of the Unit under all designed conditions and therefore
no adjustments shall be made on account of fuel quality or ambient conditions.

 

		d)	The
Seller shall perform in respect of each Unit a Performance Test, which such Unit shall be deemed to have passed if it operates
continuously for seventy two (72) consecutive hours at or above eighty (80) percent of its Contracted Capacity, as existing on
the Effective Date or in case the Seller has exercised the option under clause 3.1.1 the Contracted Capacity so finalized and
within the electrical system limits and the Functional Specifications.

 

		ii.	For
the purposes of any Performance Test pursuant to this sub-clause 1.1, the electrical system limits to be achieved shall be as
follows:

 

		a)	Voltage

 

The Unit must operate within the voltage levels
described in the Functional Specification for the duration of the Performance Test. If, during the Performance Test, voltage tests
cannot be performed due to Grid System, data supplied from tests of the generator step-up transformers and generators supplied
by the manufacturers shall be used to establish the ability of the Unit to operate within the specified voltage limits.

 

		b)	Grid
System Frequency

 

The Unit shall operate within the Grid System
frequency levels described in the Functional Specification for the duration of the Performance Test.

 

		c)	Power
Factor

 

The Unit shall operate within the power factor
range described in the Functional Specification for the duration of the Performance Test. If, during the Performance Test, power
factor tests cannot be performed due to the Grid System, data supplied from tests of the generators and the generator step-up transformers
supplied by the manufacturers shall be used to establish the ability of the Unit to operate within the specified power factor range.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	53

     

    

 

Power Purchase Agreement (PPA)

 

		d)	Fuel quality and cooling water temperature

 

The Unit must operate to its Minimum Capacity
with Fuel quality and-water temperature available at the time of Testing and no adjustment shall be allowed for any variation in
these parameters.

 

		iii.	As a part of the Performance Test, the Seller shall
demonstrate that the Unit meets the Functional Specifications for Ramping rate as mentioned in Schedule III. For this purpose,
representative samples of ramp rates shall be taken, by ramping up or down the gross turbine load while maintaining the required
temperatures and temperature differences associated with each ramp rate within the turbine while maintaining all other operational
parameters within equipment limits:

 

		1.1	Testing and Measurement procedures applied during Performance
Test shall be in accordance with codes, practices or procedures as generally/ normally applied for the Performance Tests

 

		1.2	The Seller shall comply with the prevalent Laws, rules
and regulations as applicable to the provisions contained in this Schedule, from time to time.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	54

     

    

 

Power Purchase Agreement (PPA)

 

SCHEDULE V: TARIFF

 

		1.1	General

 

		i.	The method of determination of Tariff Payments for any
Contract Year during the Term of Agreement shall be in accordance with this Schedule.

 

		ii.	The Tariff shall be paid in one single part that is Energy
Charge.

 

		iii.	For the purpose of payments, the Tariff will be Quoted
Tariff for the applicable Contract Year as per Schedule VIII.

 

		iv.	Procurer is signing this Agreement for procuring 100 %
of such available energy from the Project.

 

		1.2	Weekly Tariff Payment

 

		1.2.1	Components
of Weekly Tariff Payment

 

The Weekly Bill for any Week in a Contract Year shall consist of
only Weekly Energy Charges for Scheduled Energy;

 

		1.2.2	Weekly
Energy Charges

 

The Weekly Energy charges will be calculated as under:

 

The Weekly Energy Charges for Month “m” shall be calculated
as under: WEPm = AEOm x WEPn

 

Where:

WEPm is the Weekly Energy Charges for Week m (in US $)

AEOm is the
Scheduled Energy during the Week m (in kW-h)

WEPn is the Energy Charge,
in US $/kW-h, and is the quoted energy charges for the Contract

 

Year “n” in which Week “m” occurs and computed
as mentioned hereunder

 

		1.2.3	Transmission/Wheeling
Charges and Scheduling Charges

 

As the Energy is being directly fed to Procurer's
grid, there will be charges for sale of energy to Procurer. The payment of scheduling charges to the respective nodal agency (RLDC
or SLDC) shall be the responsibility of the Seller.

 

1.2.4             Tariff for the period prior to Scheduled COD of first unit
and for Contract Years beyond the 30 years from the COD of the first Unit

 

The Tariff for the period prior to Scheduled
COD of the first unit shall be the quoted Tariff of the first year. The Tariff for the Contract Years beyond the 30 years from
the Scheduled COD shall be the Quoted Tariff of the 30th year from the Scheduled
COD and indexed by 4.5 % per annum.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	55

     

    

 

Power Purchase Agreement (PPA)

 

SCHEDULE VI: DETAILS OF INTERCONNECTION POINT & FACILITIES

 

The Interconnection Point or Delivery Point
shall be point from where the power from the Power Station Switch Yard Bus is being injected into the transmission network. The
Procurer shall be required to provide transmission lines and associated infrastructure from the Power Station till the Procurer’s
Sub-Station.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	56

     

    

 

Power Purchase Agreement (PPA)

 

SCHEDULE VII: REPRESENTATIONS & WARRANTIES

 

		1.	Representations and Warranties by the Procurers

 

The Procurer hereby represents and warrants
to and agrees with the Seller as follows and acknowledges and confirms that the Seller is relying on such representations and warranties
in connection with the transactions described in this Agreement:

 

		1.1	The Procurer has all requisite powers authorizing and
has been duly authorized to execute and consummate this Agreement;

 

		1.2	This Agreement is enforceable against the said Procurer
in accordance with its terms;

 

		1.3	The Procurer is aware and cognizant of his obligations
and has the capacity to respect and execute same;

 

		1.4	The Procurer is not insolvent and no insolvency proceedings
have been instituted, nor threatened or pending by or against the Procurer;

 

The Procurer makes all the representations and warranties above
to be valid as of the date of signature of these presences.

 

		2.	Representation and Warranties of the Seller

 

The Seller hereby represents and warrants to
and agrees with the Procurer as follows and acknowledges and confirms that the Procurer is relying on such representations and
warranties in connection with the transactions described in this Agreement:

 

		2.1	The Seller has all requisite power authorizing and
has been duly authorized to execute and consummate this Agreement;

 

		2.2	This Agreement is enforceable against the Seller in
accordance with its terms;

 

		2.3	The Seller is aware and cognizant of his obligations
and has the capacity to respect and execute same;

 

		2.4	The Seller is not insolvent and no insolvency proceedings
have been instituted, or not threatened or pending by or against the Seller;

 

The Seller makes all the representations and
warranties above to be valid as of the date of signature of these presences.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	57

     

    

 

Power Purchase Agreement (PPA)

 

SCHEDULE VIII: QUOTED TARIFF

 

QUOTED TARIF FEE WITH ESCALATING INDEX

 

	Year from COD*	$US/kW-h	Year from COD*	$US/kW-h	Year from COD*	$US/kW-h
	1	0.14	11	0.25	21	0.45
	2	0.1475	12	0.265	22	0.47
	3	0.155	13	0.28	23	0.49
	4	0.165	14	0.295	24	0.51
	5	0.175	15	0.31	25	0.53
	6	0.185	16	0.33	26	0.55
	7	0.195	17	0.35	27	0.575
	8	0.205	18	0.37	28	0.59
	9	0.22	19	0.39	29	0.62
	10	0.235	20	0.41	30	0.65

 

*Year commencement as of COD (Date of Commissioning) of projecting,
time equals start

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	58

     

    

 

Power Purchase Agreement (PPA)

 

SCHEDULE IX: SUBSTITUTION RIGHTS OF THE LENDERS

 

		1.	Substitution of the Seller

 

		a)	Subject to the terms of this Agreement, upon occurrence
of a Seller Event of Default under this Agreement, the Lenders shall, have the right to seek substitution of the Seller by a Selectee
for the residual period of this Agreement, for the purposes of securing the payments of the Total Debt Amount from the Seller
and performing the obligations of the Seller, in accordance with the provisions of this Schedule.

 

		b)	The
Lenders may seek to exercise right of substitution by an amendment or novation of this Agreement and other Project Documents executed
between the Procurer and the Seller in favour of the Selectee, the Procurer and the Seller shall cooperate with the Lenders to
carry out such substitution.

 

		2.	Procurer's
Notice of Default

 

The Procurer (i.e. the Procurer who serves
the Preliminary Default Notice on the Seller as per this Agreement) shall, simultaneously also issue a copy of the same to the
Lenders.

 

		3.	Substitution
Notice

 

In the event of failure of the Seller to rectify
the Event of Default giving rise to Preliminary Default Notice, the lenders, upon receipt of a written advice from the Procurer
confirming such failure, either on their own or through its representative (“the Lenders' Representative”) shall
be entitled to notify the Procurer and the Seller of the intention of the Lenders to substitute the Seller by the Selectee for
the residual period of this Agreement (the “Substitution Notice”).

 

		4.	Interim operation of Project

 

		a)	On receipt of a Substitution Notice, no further action
shall be taken by any Party to terminate this Agreement, except under and in accordance with the terms of this Schedule IX of
this Agreement.

 

		b)	On issue of a Substitution Notice, the Lenders shall
have the right to request the Procurer to enter upon and takeover the Project for the interim and till the substitution of the
Selectee is complete and to otherwise take all such steps as are necessary for the continued operation and maintenance of the
Project, including levy, collection and appropriation of payments thereunder, subject to, the servicing of monies owed in respect
of the Total Debt Amount as per the Financing Agreements and the Seller shall completely cooperate in any such takeover of the
Project by the Procurer. If the Procurer, at their sole and exclusive discretion agree to enter upon and takeover the Project,
till substitution of the Selectee in accordance with this Agreement, the Procurer shall be compensated for rendering such services
in accordance with clause 10.1 herein.

 

		c)	The Lenders and the Procurer shall, simultaneously
have the right to commence the process of substitution of the Seller by the Selectee in accordance with these terms and the Seller
hereby irrevocably consents to the same.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	59

     

    

 

Power Purchase Agreement (PPA)

 

		5.	Process of Substitution of Seller

 

The Lenders' Representative may, on delivery
of a Substitution Notice notify the Procurer and the Seller on behalf of all the Lenders about the Lenders' decision to invite
and negotiate, at the cost of the Lenders, offers from third parties to act as Selectee, either through private negotiations or
public auction and / or a tender process, for the residual period of this Agreement.. Subject to and upon approval of the Procurer,
such Selectee shall be entitled to receive all the rights of the Seller and shall undertake all the obligations of the Seller under
this Agreement and other Project Documents executed between the Seller and the Procurer, in accordance with these terms of substitution.

 

The Lenders and the Seller shall ensure
that, upon the Procurer approving the Selectee, the Seller shall transfer absolutely and irrevocably, the ownership of the
Project to such Selectee simultaneously with the amendment or novation of this Agreement other Project Documents executed
between the Seller and the Procurer in favour of the Selectee as mentioned in clause.

 

		6.	Modality for Substitution

 

		6.1	Criteria for selection of the Selectee.

 

The Lenders and/or the Lenders' Representative shall in addition
to any other criteria that they may deem fit and necessary, apply the following criteria in the selection of the Selectee:

 

		a)	if the Seller is proposed to be substituted during
the Construction Period, the Selectee shall possess the technical and financial capability in accordance to the qualifying criteria
of the Procurer and Lenders, to perform and discharge all the residual duties, obligations and liabilities of the Seller under
this Agreement.

 

		b)	the Selectee shall have the capability and shall unconditionally
consent to assume the liability for the payment and discharge of dues, if any, of the Seller to the Procurer under and in accordance
with this Agreement and also payment of the Total Debt Amount to the Lenders upon terms and conditions as agreed to between the
Selectee and the Lenders;

 

		c)	the Selectee shall have not been in breach of any agreement
between the Selectee and any Bank or any Lender or between the Selectee and any of the Procurer, involving sums greater than one
million US Dollars at any time in the last two (2) years as on the date of the substitution of the Seller.

 

		d)	any other appropriate criteria, whereby continuity
in the performance of the Selectee's obligations under this Agreement is maintained and the security in favour of the Lenders
under the Financing Agreements is preserved.

 

		7.	Modalities

 

The following modalities shall be applicable
to any substitution of the Seller by the Selectee pursuant to this Agreement:

 

		7.1	The Lenders' Representative shall on behalf of the Lenders
propose to the Procurer (the “Proposal”) pursuant to sub-clause 7.2 below, the name of the Selectee for acceptance,
seeking:

 

		a)	grant of all the rights and obligations under this
Agreement and the other Project Documents executed between the Procurer and the Seller, to the Selectee (as substitute for the
Seller);

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	60

     

    

 

Power Purchase Agreement (PPA)

 

		b)	amendment of this Agreement and the other Project Documents
executed between the Procurer and the Seller, to the effect that the aforementioned grant to the Selectee, shall be such that
the rights and obligations assumed by the Selectee are on the same terms and conditions for the residual period of this Agreement
as existed in respect of the Seller under the original Agreement and the other Project Documents executed between the Procurer
and the Seller; and

 

		7.2	The Proposal shall contain the particulars and information
in respect of the Selectee the data and information as the Procurer may reasonably require..

 

		7.3	The Proposal shall be accompanied by an irrevocable
and unconditional undertaking by the Selectee that it shall, upon approval by the Procurer of the Proposal:

 

		a)	observe, comply, perform and fulfill the terms, conditions
and covenants of this Agreement and all Project Documents executed between Seller and the Procurer or a new power purchase agreement
or respective Project Document (in the case of the novation thereof), which according to the terms therein are required to be
observed, complied with, performed and fulfilled by the Seller, as if such Selectee was the Seller originally named under this
Agreement; or the respective Project Document; and

 

		b)	be liable for and shall assume, discharge and pay the
Total Debt Amount or then outstanding dues to the Lenders under and in accordance with the Financing Agreements or in any other
manner agreed to by the Lenders and the Procurer as if such Selectee was the Seller originally named under such Financing Agreements.

 

		7.4	At any time prior to taking a decision in respect of
the Proposal received under clause 7.1, the Procurer may require the Lender / Lenders' Representative to satisfy it as to the
eligibility of the Selectee. The decision of the Procurer as to acceptance or rejection of the Selectee, shall be made reasonably
and when made shall be final, conclusive and binding on the Parties.

 

		7.5	Such decision shall be made by the Procurer at their
reasonably exercised discretion within seven (7) days of:

 

		a)	the date of receipt of the Proposal by the Procurer;
or

 

		b)	the date when the last of further and other information
and clarifications in respect of any data, particulars or information included in the Proposal requested by the Procurer under
clause 7.2 above is received; whichever is later.

 

Notwithstanding anything to the contrary mentioned
in this Agreement, the approval of the Procurer for the select shall not be withheld in case the seller meets the mentioned in
clause 6.1.

 

		7.6	Upon approval of the Proposal and the Selectee by the
Procurer, the Selectee mentioned in the Proposal shall become the Selectee.

 

		7.7	Following the rejection of a Proposal, the Lenders
and/or the Lenders' Representative shall have the right to submit a fresh Proposal, proposing another Selectee. The provisions
of this schedule shall apply mutatis mutandis to such fresh Proposal.

 

		7.8	The substitution of the Seller by the Selectee shall
be deemed to be complete upon the Selectee executing all necessary documents and writings with or in favour of the Seller, Procurer
and the Lenders so as to give full effect to the terms and conditions of the substitution, subject to which the Selectee has been
accepted by the Lenders and the Procurer and upon transfer of ownership and complete possession of the Project by the
Procurer or the Seller, as the case may be, to the Selectee. The Procurer shall novate all the Project Documents, which they had
entered in to with the Seller in order to make the substitution of the Seller by the Selectee effective.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	61

     

    

 

Power Purchase Agreement (PPA)

 

		7.9	Upon the substitution becoming effective pursuant to
sub-clause 7.8 above, all the rights of the Seller under this Agreement shall cease to exist:

 

Provided that, nothing contained in this sub-clause
shall prejudice any pending/subsisting claims of the Seller against the Procurer or any claim of the Procurer against the erstwhile
Seller or the Selectee.

 

		7.10	The Selectee shall, subject to the terms and conditions
of the substitution, have a period of ninety (90) days to rectify any breach and / or default of the Seller subsisting on the
date of substitution and required to be rectified and shall incur the liability or consequence on account of any previous breach
and / or default of the Seller.

 

		7.11	The decision of the Lenders and the Procurer in the
selection of the Selectee shall be final and binding on the Seller and shall be deemed to have been made with the concurrence
of the Seller. The Seller expressly waives all rights to object or to challenge such selection and appointment of the Selectee
on any ground whatsoever.

 

		7.12	All actions of the Lenders' Representative hereunder
shall be deemed to be on behalf of the Lenders and shall be binding upon them. The Lenders' Representative shall be authorized
to receive payment of compensation and any other payments, including the consideration for transfer, if any, in accordance with
the Proposal and the Financing Agreements and shall be bound to give valid discharge on behalf of all the Lenders.

 

		8.	Seller's Waiver

 

		8.1	The Seller irrevocably agrees and consents to any
actions of the Lenders, the Lender's Representative and the Procurer or exercise of their rights under and in accordance with
these terms.

 

		8.2	The Seller irrevocably agrees and consents that from
the date specified in clause 7.9, it shall cease to have any rights under this Agreement or the Financing Agreements.

 

		8.3	The Seller warrants and covenants that any agreement
entered into by the Seller, in relation to the Project, shall include a legally enforceable clause providing for automatic novation
of such agreement in favour of the Selectee, at the option of the Lenders or the Procurer. The Seller further warrants and covenants
that, in respect of any agreements which have already been executed in relation to the Project and which lack a legally enforceable
clause providing for automatic novation of such agreement, the Procurer shall procure an amendment in the concluded agreement
to incorporate such clause.

 

		9.	Interim Protection

 

		9.1	Appointment of a Receiver

 

		a)	In every case of the Lenders issuing a Substitution
Notice and the Procurer refusing to take over the Project and the Seller failing to operate the Project in accordance with clause
4 (c) above and the Procurer not electing to act as Receiver as per sub-clause 9.1 (b) hereof, the Lenders may institute protective
legal proceedings for appointment of a receiver (the “Receiver”) to maintain, preserve and protect the assets
held as security by the Lenders if such right is granted under the terms of the Financing Agreements.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	62

     

    

 

Power Purchase Agreement (PPA)

 

		b)	Provided that in event of the Procurer refusing to
take over the Project and the Seller failing to operate the Project in accordance with clause 4 (c) above, and if the assets of
the Project are, in the opinion of the Procurer, necessary and required for the operation and maintenance of the Project, the
Procurer shall be entitled to elect to act as the Receiver for the purposes of this clause and be entitled to maintain, preserve
and protect the said assets by engaging an operator/service provider to act on their behalf and the Lenders and Seller hereby
consent and agree to the same. Upon the Procurer so intimating the Seller and the Lender's representative their desire to act
as Receiver, the Seller and the Lender's representative shall co-operate with the Procurer to facilitate the same.

 

		c)	Upon appointment of the Court appointed Receiver or
the Procurer acting as Receiver, all the Receivables received by such Receiver shall be deposited by the Receiver in the bank
account jointly designated by the Procurer and the Lenders. The Receiver shall be responsible for protecting the assets in receivership
and shall render a true and proper account of the receivership to the lenders in accordance with the terms of its appointment.

 

		d)	When acting as a Receiver or operator in accordance
with this Article 9 or clause 4 (b), the Procurer shall be entitled to be remunerated for such services as may be determined by
Central Electricity Regulatory Commission. Furthermore, when acting as a Receiver, the Procurer shall not be liable to the Lenders,
the Lenders' Representative, Seller or any third party for any default under this Agreement, damage or loss to the Power Station
or for any other reason whatsoever, except for willful default of the Procurer.

 

		10.	Change in the Procurer or Lenders

 

The Parties hereto acknowledge that during
the subsistence of this Agreement, it is possible that the Procurer may cease to be a party to this Agreement by reason of termination
of this Agreement and any Lender may cease to remain as a Lender by reason of repayment of the debt or otherwise. Further it may
possible that any Lender may be substituted or a new Lender may be added. In the event of any Procurer ceasing to be a party to
this Agreement or Financing Agreement respectively, the term and conditions as prescribed in this Schedule shall cease to automatically
apply to such Procurer or Lender as the case may be. Further, upon any entity being added as a Lender and in the event such entity
is given the right to substitute the Seller under the Financing Agreement and then the contents of this Schedule shall be applicable
to the exercise of such right by the said new entity.

 

	Initials: __________	Initials: __________
	Strictly Confidential	Property of BioCrude Technologies, Inc.

 

    	63

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00272-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00272-of-00352.parquet"}]]