Document:

EX-10.1

 Exhibit 10.1 

Building C 
  

LEASE 
 BY AND BETWEEN

 Santa Clara Campus Property Owner I LLC, 

a Delaware limited liability company 

as Landlord 
 and

 Aruba Networks, Inc., 

a Delaware corporation 

as Tenant 
 April 15,
2015 

 Building C 
  

TABLE OF CONTENTS 
  

							
	 	 	 	  	Page	 
	 ARTICLE 1
	 	        REFERENCE	  	 	1	  
	        1.1	 	References	  	 	1	  
			
	 ARTICLE 2
	 	        LEASED PREMISES, TERM AND POSSESSION	  	 	6	  
	        2.1	 	Demise Of Leased Premises	  	 	6	  
	        2.2	 	Right To Use Common Areas	  	 	6	  
	        2.3	 	Lease Commencement Date And Lease Term	  	 	7	  
	        2.4	 	Delivery Of Possession	  	 	7	  
	        2.5	 	Performance Of Tenant Improvement Work; Acceptance Of Possession	  	 	8	  
	        2.6	 	Surrender Of Possession	  	 	8	  
			
	 ARTICLE 3
	 	        RENT	  	 	10	  
	        3.1	 	Base Monthly Rent	  	 	10	  
	        3.2	 	Additional Rent	  	 	10	  
	        3.3	 	Year-End Adjustments	  	 	11	  
	        3.4	 	Late Charge, And Interest On Rent In Default	  	 	11	  
	        3.5	 	Payment Of Rent	  	 	12	  
			
	 ARTICLE 4
	 	        USE OF LEASED PREMISES AND COMMON AREA	  	 	12	  
	        4.1	 	Permitted Use	  	 	12	  
	        4.2	 	General Limitations On Use	  	 	12	  
	        4.3	 	Noise And Emissions	  	 	12	  
	        4.4	 	Trash Disposal	  	 	12	  
	        4.5	 	Parking	  	 	13	  
	        4.6	 	Signs	  	 	13	  
	        4.7	 	Compliance With Laws And Restrictions	  	 	13	  
	        4.8	 	Compliance With Insurance Requirements	  	 	14	  
	        4.9	 	Landlord’s Right To Enter	  	 	14	  
	        4.10	 	Use Of Common Areas	  	 	14	  
	        4.11	 	Environmental Protection	  	 	14	  
	        4.12	 	Rules And Regulations	  	 	16	  
	        4.13	 	Reservations	  	 	16	  
			
	 ARTICLE 5
	 	        REPAIRS, MAINTENANCE, SERVICES AND UTILITIES	  	 	17	  
	        5.1	 	Repair And Maintenance	  	 	17	  
		 	 (a)    Tenant’s Obligations
	  	 	17	  
		 	 (b)    Landlord’s Obligation
	  	 	17	  
	        5.2	 	Utilities	  	 	18	  
	        5.3	 	Security	  	 	19	  
	        5.4	 	Energy And Resource Consumption	  	 	19	  
	        5.5	 	Limitation Of Landlord’s Liability	  	 	19	  
			
	 ARTICLE 6
	 	        ALTERATIONS AND IMPROVEMENTS	  	 	19	  
	        6.1	 	By Tenant	  	 	19	  
	        6.2	 	Ownership Of Improvements	  	 	20	  
	        6.3	 	Alterations Required By Law	  	 	20	  
	        6.4	 	Liens	  	 	21	  
			
	 ARTICLE 7
	 	        ASSIGNMENT AND SUBLETTING BY TENANT	  	 	21	  
	        7.1	 	By Tenant	  	 	21	  
	        7.2	 	Merger, Reorganization, or Sale of Assets	  	 	22	  
	        7.3	 	Landlord’s Election	  	 	22	  
	        7.4	 	Conditions To Landlord’s Consent	  	 	23	  
	        7.5	 	Assignment Consideration And Excess Rentals Defined	  	 	24	  
	        7.6	 	Payments	  	 	24	  
	        7.7	 	Good Faith	  	 	24	  
	        7.8	 	Effect Of Landlord’s Consent	  	 	24	  

  
 i 

 Building C 
  

 

							
			
	 ARTICLE 8
		        LIMITATION ON LANDLORD’S LIABILITY AND INDEMNITY		 	26	  
	        8.1		Limitation On Landlord’s Liability And Release		 	26	  
	        8.2		Tenant’s Indemnification Of Landlord		 	26	  
			
	 ARTICLE 9
		        INSURANCE		 	26	  
	        9.1		Tenant’s Insurance		 	26	  
	        9.2		Landlord’s Insurance		 	27	  
	        9.3		Mutual Waiver Of Subrogation		 	28	  
			
	 ARTICLE 10
		        DAMAGE TO LEASED PREMISES 		 	28	  
	        10.1		Landlord’s Duty To Restore		 	28	  
	        10.2		Insurance Proceeds		 	28	  
	        10.3		Landlord’s Right To Terminate		 	29	  
	        10.4		Tenant’s Right To Terminate		 	29	  
	        10.5		Tenant’s Waiver		 	29	  
	        10.6		Abatement Of Rent		 	30	  
			
	 ARTICLE 11
		        CONDEMNATION		 	30	  
	        11.1		Tenant’s Right To Terminate		 	30	  
	        11.2		Landlord’s Right To Terminate		 	30	  
	        11.3		Restoration		 	30	  
	        11.4		Temporary Taking		 	30	  
	        11.5		Division Of Condemnation Award		 	31	  
	        11.6		Abatement Of Rent		 	31	  
	        11.7		Taking Defined		 	31	  
			
	 ARTICLE 12
		        DEFAULT AND REMEDIES		 	31	  
	        12.1		Events Of Tenant’s Default		 	31	  
	        12.2		Landlord’s Remedies		 	32	  
	        12.3		Landlord’s Default And Tenant’s Remedies		 	33	  
	        12.4		Limitation Of Tenant’s Recourse		 	34	  
	        12.5		Tenant’s Waiver		 	34	  
			
	 ARTICLE 13
		        GENERAL PROVISIONS		 	34	  
	        13.1		Taxes On Tenant’s Property		 	34	  
	        13.2		Holding Over		 	35	  
	        13.3		Subordination To Mortgages		 	35	  
	        13.4		Tenant’s Attornment Upon Foreclosure		 	36	  
	        13.5		Mortgagee Protection		 	36	  
	        13.6		Estoppel Certificate		 	36	  
	        13.7		Tenant’s Financial Information		 	36	  
	        13.8		Transfer By Landlord		 	37	  
	        13.9		Force Majeure		 	37	  
	        13.10		Notices		 	37	  
	        13.11		Attorneys’ Fees and Costs		 	38	  
	        13.12		Definitions		 	38	  
			 (a)    Real Property Taxes
		 	38	  
			 (b)    Landlord’s Insurance Costs
		 	39	  
			 (c)    Property Maintenance Costs
		 	39	  
			 (d)    Property Operating Expenses
		 	40	  
			 (e)    Law
		 	43	  
			 (f)     Lender
		 	43	  
			 (g)    Rent
		 	43	  
			 (h)    Restrictions
		 	43	  
	        13.13		General Waivers		 	43	  
	        13.14		Miscellaneous		 	43	  
	        13.15		Patriot Act Compliance		 	44	  
			
	 ARTICLE 14
		        LEGAL AUTHORITY BROKERS AND ENTIRE AGREEMENT		 	45	  
	        14.1		Legal Authority		 	45	  
	        14.2		Brokerage Commissions		 	45	  

  
 ii 

 Building C 
  

							
	        14.3		Entire Agreement		 	46	  
	        14.4		Landlord’s Representations		 	46	  
			
	 ARTICLE 15
		        OPTIONS TO EXTEND		 	46	  
	        15.1		Option to Extend		 	46	  
	        15.2		Fair Market Rent		 	46	  
	        15.3		Tenant’s Election		 	47	  
	        15.4		Rent Arbitration		 	47	  
			
	 ARTICLE 16
		        TELEPHONE SERVICE		 	48	  

  
 iii 

 Building C 
  

LEASE 
 THIS LEASE,
dated April 15, 2015 for reference purposes only, is made by and between SANTA CLARA CAMPUS PROPERTY OWNER I LLC, a Delaware limited liability company
(“Landlord”) and ARUBA NETWORKS, INC., a Delaware corporation [NASDAQ: ARUN] (“Tenant”), to be effective and binding upon the parties as of the date the last of
the designated signatories to this Lease shall have executed this Lease (the “Effective Date of this Lease”). 
 ARTICLE
1 
 REFERENCE 

1.1 References. All references in this Lease (subject to any further clarifications contained in this Lease) to the following terms
shall have the following meaning or refer to the respective address, person, date, time period, amount, percentage, calendar year or fiscal year as below set forth: 
  

			
	Tenant’s Representative:		Michael Phelps
		
	Phone Number:		(408) 419-0296
		
	Landlord’s Representative:		Henry Bullock/Richard Holmstrom
		
	Phone Number:		(650) 326-9300
		
	Targeted Commencement Date:		March 1, 2017
		
	Intended Term:		One hundred thirty-two (132) months
		
	Lease Expiration Date:		One hundred thirty-two (132) months from the Lease Commencement Date (defined in Paragraph 2.3 below), unless earlier terminated in accordance with the terms of this Lease, or extended by Tenant pursuant to Paragraph 2.3 or Article
15 below. Notwithstanding the foregoing or any other provision of this Lease, if the Lease Commencement Date is other than the first calendar day of a calendar month, then the Lease Expiration Date shall be one hundred thirty-two (132) months from
the last calendar day of the calendar month in which the Lease Commencement Date occurs, subject to the terms of Paragraph 2.3 and Article 15 below.
		
	Options to Extend:		Two (2) option(s) to extend, each for a term of five (5) years.
		
	Tenant’s Security Deposit:		None
		
	Late Charge Amount:		Five Percent (5%) of the Delinquent Amount
		
	Tenant’s Required Liability Coverage:		$5,000,000 Combined Single Limit
		
	Tenant’s Broker:		Jones Lang LaSalle
		
	Landlord’s Broker:		Colliers International
		
	Project:		 That certain real property situated in the City of Santa Clara, County of Santa Clara, State of California, identified as Assessor’s
Parcel Nos.:
  
 (1) 216-31-084, with a street address of 3355 Scott Boulevard (shown on
the Site Plan as the location of “Building A”),
  
 (2) 216-31-085, with a
street address of 3325 Scott Boulevard (shown on the Site Plan as the location of “Building B” and most of “Building D”),
  

(3) 216-31-086, with a street address of 3315 Scott Boulevard (shown on the Site Plan as the location of “Building C” and the balance of
“Building D”),
  
 (4) 216-31-083, shown on the Site Plan as the location of
future “Building E” and future “Building F” with a current with a street address of 3335 Scott Boulevard but which address will change after completion of the adjustments described below in the definition of
“property”,

  
 1 

 Building C 
  

			
		
			 and
  

(5) 216-31-082, with a current street address of 3345 Scott Boulevard (shown on the Site Plan as the location of the future “Parking Structure”), and
such other buildings as Landlord may elect to construct in the future,

		
			which real property is shown on the preliminary Site Plan attached hereto as Exhibit A (the “Site Plan”). Construction will commence on Building D after the Effective Date of this Lease. Future Building E
(“Building E”), future Building F (“Building F”), and future Parking Structure (“Parking Structure”) have not yet been constructed and Landlord may elect not to construct them; provided however that
if Landlord elects not to construct the Parking Structure, Landlord shall install surface parking sufficient to satisfy a parking ratio of 3.3 parking spaces per 1,000 rentable square feet of space constructed in the Project, and a minimum of 3.3
parking spaces for each 1,000 rentable square feet of Leased Premises shall continue to be located within the area depicted by a curved dotted line on Schedule 2.2(a) attached to the Lease. Landlord reserves the right to adjust the boundaries
of the Project and the sizes and locations of Building E, Building F, and the Parking Structure at any time, provided that the Required Conditions are satisfied. The Site Plan and Landlord’s proposed adjustments to it and the applicable
Assessor’s Parcel Map are subject to approval by the City of Santa Clara.
		
	Property:		That certain separate legal parcel of real property currently identified as Assessor’s Parcel
No. 216-31- 086, on which is situated the Building and a portion of Building D as delineated on the Site Plan, with a street
address of 3315 Scott Boulevard, Santa Clara, California. Landlord is currently processing adjustments to the boundaries of the Property so Building D will not be located on the Property, and reserves the right to adjust the boundaries of the
Property at any time, provided in all cases that the Required Conditions are satisfied.
		
	Building:		That certain building located on the Property in which the Leased Premises will be located commonly known as 3315 Scott Boulevard, Santa Clara, California (the “Building”), which Building is shown outlined on the
Site Plan (and denoted thereon as “Building C”), containing approximately 156,889 rentable square feet of space, which rentable square footage has been determined by utilizing the Building Owners and Managers Association International
Single Tenant Full Building Standard Method for Measuring Floor Area in Office Buildings ANSI Z65-1-1996, pages 10 and 11 (the “BOMA”), and to which has been added a proportionate share of café and the fitness center in the
Other Building located at 3355 Scott Boulevard (the “Cafe & Fitness Center”), which will be allocated across the rentable square footage of the Building and the Other Buildings, bringing the total rentable square footage of the
Building to approximately 156,889 and, for purposes of this Lease, the Building is agreed to contain said number of rentable square feet.
		
	Other Buildings:		(a) Those certain buildings currently constructed in the Project (but outside the Property) commonly known as 3355 Scott Boulevard (“Building A”), containing approximately 144,499 rentable square feet of space, 3325
Scott Boulevard (“Building B”), containing approximately 157,412 rentable square feet of space, and 3335 Scott Boulevard (“Building D”), containing (once construction is completed) approximately 245,804 rentable
square feet of space, as such rentable

  
 2 

 Building C 
  

			
		
			square footage amounts were determined (with respect to Building A and Building B) and will be determined (with respect to Building D) based on BOMA (to which has been added, or subtracted in the case of Building A, a proportionate
share of the Cafe & Fitness Center as described above) and, for purposes of this Lease, Building A and Building B are agreed to contain said number of rentable square feet, and (b) such other buildings as may be built on the Project from time to
time.
		
	Building D Lease:		That certain Lease dated as of the date of this Lease, entered into by and between Landlord and Tenant for the first through fifth floors of Building D (the “Building D Lease”).
		
	Building D Premises:		The premises leased by Tenant pursuant to the Building D Lease (the “Building D Premises”).
		
	Common Areas:		The “Common Areas” shall mean the areas within the Building or the Project not reserved for the exclusive use of Landlord, Tenant or any other tenant, including, without limitation, lobbies, plazas, walkways,
private roadways, loading docks, parking areas, parking structures, and landscaped areas. Common Areas shall not include the interior of any Other Buildings, other than such portions thereof as Landlord may designate for the use of all occupants of
the Property.
		
	Parking:		With respect to the Leased Premises, Tenant shall be entitled to utilize 3.3 unreserved and unassigned parking spaces for each 1,000 rentable square feet of Leased Premises (as the same may change from time to time in accordance
with the terms of this Lease or an amendment hereto), such spaces to be located in the parking area of the Common Areas. For the avoidance of confusion, so long as Tenant is leasing the entire Leased Premises of 35,121 rentable square feet, Tenant
would be entitled to 116 such parking spaces. Tenant may (within sixty (60) days after the Effective Date of this Lease, if at all) designate up to three (3) site standard parking spaces (out of Tenant’s overall parking count described above)
within the area noted on the Site Plan as “Available Exclusive Parking Area,” for Tenant’s exclusive use so long as it is in occupancy of the entire initial Leased Premises (“Tenant’s Exclusive Parking Spaces”).
In addition, if Tenant so desires, Tenant may elect (within sixty (60) days after the Effective Date of this Lease, if at all) to have Landlord designate up to an additional two (2) site standard parking spaces (out of Tenant’s overall parking
count described above) to be for Tenant’s exclusive use so long as it is in occupancy of the entire initial Leased Premises (“Tenant’s Additional Exclusive Parking Spaces”). In the event Tenant at any time leases less than
the entire initial Leased Premises, the number of Tenant’s Exclusive Parking Spaces and Tenant’s Additional Exclusive Parking Spaces shall be proportionately reduced. Parking is provided to Tenant by Landlord without additional charge for
the entire Lease Term including any expansion and/or extension periods, including but not limited to the First Extension Period and the Second Extension Period (as defined in Article 15 below).
		
	Required Conditions:		The term “Required Conditions” is defined in Paragraph 2.2(a) below).

  
 3 

 Building C 
  

			
		
	Building Standard Hours:		The term “Building Standard Hours” means from 7:00 a.m. and 7:00 p.m. Monday through Friday and on Saturdays from 8:00 a.m. to noon, excluding Sundays and New Year’s Day, Presidents Day, Memorial Day,
Independence Day, Labor Day, Thanksgiving, Christmas and such other holidays as are generally recognized in the vicinity of the Project.
		
	HVAC:		Heating, ventilating, and/or air conditioning.
		
	Leased Premises:		The space located on the first floor of the Building and shown on the floor plan attached hereto as Exhibit B, plus the load factor associated therewith, estimated to contain approximately 35,121 rentable square feet, which
rentable square footage has been determined by utilizing Landlord’s method of measurement (the “Premises Measurement Method”), which has been explained to Tenant, which is illustrated on Exhibit C attached hereto. Such
rentable area calculation includes, without limitation, a proportionate share of the common Building lobby, and (i) the café portion of the Cafe & Fitness Center allocated across the rentable square footage of the Building and Buildings A
and B, and (ii) the fitness center portion of the Cafe & Fitness Center allocated across the rentable square footage of the Building and Buildings A, B, and D.
		
			The Building and the Leased Premises are not subject to re-measurement unless, pursuant to a written amendment to this Lease, space is subtracted therefrom or additional space is added thereto. Recognizing that both Landlord and
Tenant have agreed to the foregoing rentable square footage number and have agreed that there will be no re-measurement except as expressly provided above, Landlord has given Tenant the opportunity to measure the Building and the Leased Premises and
has encouraged Tenant to do so, and Tenant hereby confirms that it has measured the Building and the Leased Premises and is in agreement with the foregoing number of square feet.
		
			  
 Tenant’s
Initials

		
	Work Letter:		The term “Work Letter” shall mean the Work Letter attached as Exhibit D to and made a part of this Lease, the terms and provisions of which are hereby incorporated into this Lease.
		
	Tenant’s Building Share:		The term “Tenant’s Building Share” shall mean the percentage obtained by dividing the rentable square footage of the Leased Premises at the time of calculation by the rentable square footage of the Building at
the time of calculation. Such percentage is 22.39%. In the event that the rentable square footage of the Leased Premises or the Building is changed (other than by mere re-measurement), Tenant’s Building Share shall be recalculated to equal the
percentage described in the first sentence of this paragraph, so that the aggregate Tenant’s Building Share of all tenant space in the Building shall equal 100% (calculated as if the Building were fully occupied). Landlord and Tenant agree that
any mere re-measurement, as opposed to an actual physical change, shall not result in a change in rentable square footage.

  
 4 

 Building C 
  

 

			
	Tenant’s Project Share:	  	The term “Tenant’s Project Share” shall mean the percentage obtained by dividing the rentable square footage of the Leased Premises at the time of calculation by the rentable square footage of the Building and
the Other Buildings at the time of calculation. Such percentage is currently 4.98%. In the event that any portion of the Project is sold by Landlord, or if new improvements are constructed on the Project, or if the rentable square footage of the
Leased Premises, the Building, or the Other Buildings is otherwise changed (other than by mere re-measurement), Tenant’s Project Share shall be recalculated to equal the percentage described in the first sentence of this paragraph, so that the
aggregate Tenant’s Project Share of all tenant space in the Project shall equal 100% (calculated as if the Building and the Other Buildings were fully occupied). Landlord and Tenant agree that any mere re-measurement (as opposed to an actual
physical change) shall not result in a change in rentable square footage.
		
	Standard Interest Rate:	  	The term “Standard Interest Rate” shall mean the greater of (a) 6%, or (b) the sum of that rate quoted by Wells Fargo Bank, N.T. & S. A., from time to time as its prime rate, plus two percent (2%), but in no
event more than the maximum rate of interest not prohibited or made usurious.
		
	Default Interest Rate:	  	The term “Default Interest Rate” shall mean the Standard Interest Rate, plus five percent (5%), but in no event more than the maximum rate of interest not prohibited or made usurious.
		
	Base Monthly Rent:	  	The term “Base Monthly Rent” shall mean the following:

  

									
	 Period
	  	Base Monthly
Rent per
rentable
square foot
(rounded)*	 	  	Base Monthly
Rent	 
	 Months 1-9
	  	$	2.90	  	  	$	0.00	  
	 Months 10-24
	  	$	2.90	  	  	$	101,850.90	  
	 Months 25-36
	  	$	2.97	  	  	$	104,142.55	  
	 Months 37-48
	  	$	3.03	  	  	$	106,485.75	  
	 Months 49-60
	  	$	3.10	  	  	$	108,881.68	  
	 Months 61-72
	  	$	3.17	  	  	$	111,331.52	  
	 Months 73-84
	  	$	3.24	  	  	$	113,836.48	  
	 Months 85-96
	  	$	3.31	  	  	$	116,397.80	  
	 Months 97-108
	  	$	3.39	  	  	$	119,016.75	  
	 Months 109-120
	  	$	3.47	  	  	$	121,694.63	  
	 Months 121-132
	  	$	3.54	  	  	$	124,432.76	  

  

	 	*	These “per square foot” numbers are rounded. Actual numbers used for Base Monthly Rent are to equal rentable square footage of 35,121 multiplied by $2.90 in months 10-24, and then increased by 2.25% each year
thereafter. 

  
 5 

 Building C 
  

 

			
	Permitted Use:		General office, administration, research and development, engineering laboratories, and other legal uses ancillary thereto, to the extent all such uses are in compliance with all Laws and Restrictions.
		
	Exhibits:		The term “Exhibits” and “Schedules” shall mean the Exhibits and Schedules of this Lease which are described as follows:
		
			Schedule 2.1 – Existing Title Encumbrances
		
			Schedule 2.2(a) – Approved Parking Area
		
			Exhibit A – Site Plan showing the Project and delineating the Building in which the Leased Premises are located
		
			Exhibit B – Floor Plan
		
			Exhibit C – Premises Measurement Method
		
			Exhibit D – Work Letter
		
			Exhibit E – Lease Commencement Date Certificate
		
			Exhibit F – Reserved
		
			Exhibit G – Lump Sum Payment Amendment
		
			Exhibit H – Building Signage Exhibit
		
			Exhibit I – Subordination, Nondisturbance and Attornment Provisions
		
			Exhibit J – Form of Tenant Estoppel Certificate

 ARTICLE 2 

LEASED PREMISES, TERM AND POSSESSION 

2.1 Demise Of Leased Premises. Landlord hereby leases to Tenant and Tenant hereby leases from Landlord, for the Lease Term and
upon the terms and subject to the conditions of this Lease, that certain interior space described in Article 1 as the Leased Premises, reserving and excepting to Landlord the right to fifty percent (50%) of all assignment consideration and
excess rentals as provided in Article 7 below. Tenant’s lease of the Leased Premises, together with the appurtenant right to use the Common Areas as described in Paragraph 2.2 below, shall be conditioned upon and be subject to the continuing
compliance by Tenant with (i) all the terms and conditions of this Lease, (ii) all Laws and Restrictions governing the use or occupancy of the Leased Premises, the Property, and the Project, (iii) all easements and other matters now
of public record respecting the use of the Leased Premises, the Property, and the Project, shown on Schedule 2.1 attached hereto (the “Existing Title Encumbrances”), and (iv) all reasonable, non-discriminatory rules and
regulations from time to time established by Landlord. Notwithstanding any provision of this Lease to the contrary, Landlord hereby reserves to itself and its other tenants all rights of access, use and occupancy of the Building roof, and Tenant
shall have no right of access, use or occupancy of the Building roof except as provided for in Paragraph 4.14 below; provided, however, during the period, if any, that Tenant is leasing one hundred percent (100%) of all of the rentable
square footage in the Building, Tenant shall have the exclusive right to one hundred percent (100%) of the Available Rooftop Space (as defined in Paragraph 4.14 below). 

2.2 Common Areas, Cafe & Fitness Center, and Exclusive Use Area.  

(a) As an appurtenant right to Tenant’s right to the use and occupancy of the Leased Premises, Tenant shall have the right to use the
Common Areas in conjunction with its use of the Leased Premises solely for the purposes for which they were designed and intended and for no other purposes whatsoever. Tenant’s right to so use the Common Areas shall terminate concurrently with
any termination of this Lease. Further, Landlord shall have the right, from time to time, to reconfigure the Common Areas or modify the size of the Common Areas in connection with new construction on the Project or sales or subdivisions of portions
of the Project, provided that the following conditions (the “Required Conditions”) are satisfied: (i) Tenant’s access to the Leased Premises (including access through the lobby and the elevators of the Building) or
Tenant’s access to the number of parking spaces 

  
 6 

 Building C 
  

provided to Tenant hereunder, are not materially adversely affected thereby, (ii) Tenant’s parking allocation under Article 1 hereof is not reduced
thereby, (iii) a minimum of 3.3 parking spaces for each 1,000 net rentable square feet of Leased Premises continue to be located within the area depicted by a curved dotted line on Schedule 2.2(a) attached to this Lease, (iv) Tenant
shall have access to: (A) the Cafe & Fitness Center contemplated by Paragraph 2.2(b) below, (B) if applicable, the Exclusive Use Areas described in Paragraph 2.2(c) below, and (v) the exterior Common Area in the proximity of
the Building continues to be consistent in quality and design with that existing as of the Effective Date of this Lease. 
 (b)
Additionally, on the Lease Commencement Date, Tenant shall have the right to use the Cafe & Fitness Center solely for the purposes for which they were designed and intended and for no other purposes whatsoever. Tenant’s right to use
the Cafe & Fitness Center shall be subject to such reasonable rules and regulations as Landlord or its vendors may issue from time to time, provided that in no event shall Landlord charge Tenant or any Tenant Party a fee for the use of the
Cafe & Fitness Center. Tenant’s right to use the Cafe & Fitness Center shall terminate concurrently with any termination of this Lease. Landlord retains the right to relocate the Cafe & Fitness Center to another
location on the Project (and change the size of the Cafe & Fitness Center if it is relocated), so long as the Required Conditions are satisfied, the size is not reduced by more than ten percent (10%) and, in the event of any such
change, the quality and nature of the facilities provided in the Cafe & Fitness Center at such new location shall not be materially diminished. If Landlord exercises this option, the rentable area of the Leased Premises, Base Monthly Rent,
and Tenant’s Building Share and Tenant’s Property Share shall be adjusted accordingly, based on the Premises Measurement Method. 

(c) So long as Tenant is leasing at least one (1) full floor of the Building and five (5) full floors of Building D, Tenant will
have exclusive access to the areas in the general locations denoted on the Site Plan as “Exclusive Use Areas” (and defined herein as the “Exclusive Use Common Areas”) for purposes of developing its own exterior eating area
and two (2) sport courts. 
 2.3 Lease Commencement Date And Lease Term. Subject to Paragraph 2.4 below, the term of this
Lease shall begin, and the Lease Commencement Date shall be deemed to have occurred, on the later of (a) March 1, 2017, (b) the date that the Landlord’s Additional Work is substantially completed, and (c) ninety
(90) days after Landlord has delivered the Leased Premises to Tenant in the condition required by Paragraph 2.4(c) below, subject to extension for Landlord Delays (as defined in Paragraph 7of the Work Letter) and for up to twenty (20) days
of Unavoidable Tenant Improvement Delays, as defined in Paragraph 8 of the Work Letter (such later date, the “Lease Commencement Date”). Notwithstanding the foregoing or any other contrary or inconsistent provision of this Lease, if
the date upon which Tenant occupies the Leased Premises for the purpose of conducting business occurs earlier than the Lease Commencement Date as defined in the prior sentence, then such date Tenant so occupies the Leased Premises shall be the Lease
Commencement Date. The term of this Lease shall in all events end on the Lease Expiration Date (as set forth in Article 1, as the same may be extended pursuant to Article 15 below); provided, however, that if the Lease Expiration Date of this
Lease or the Building D Lease shall not be simultaneous because of any differences in the dates on which Landlord delivers this Leased Premises and the Building D Leased Premises to Tenant, then, at Tenant’s option, which option must be
exercised by written notice thereof to Landlord delivered no later than the Lease Commencement Date of the later of such leases to commence, the Lease Expiration Date of this Lease or the Building D Lease, as relevant, shall be extended such that
the Lease Expiration Date of both this Lease and the Building D Lease shall be upon the later Lease Expiration Date of this Lease or the Building D Lease. The Lease Term shall be that period of time commencing on the Lease Commencement Date and
ending on the Lease Expiration Date (the “Lease Term”). Promptly after the Lease Commencement Date has been determined, Landlord and Tenant shall execute and deliver a Lease Commencement Date Certificate in the form of Exhibit E
attached hereto. 
 2.4 Delivery Of Possession.  

(a) Landlord has constructed the Building as described in Paragraph 1(a) of the Work Letter and shall deliver the Leased Premises to Tenant on
the date (the “Delivery Date”) that the Landlord’s Additional Work (as defined in Paragraph 1(b) of the Work Letter), but excluding the upgrade of the base building transformer, is substantially completed. Landlord currently
estimates that the Delivery Date will occur during the month of November, 2015, and that the upgrade of the base building transformer will be completed during the month of July, 2016. 

(b) [Reserved] 
 (c) In
addition, on or prior to March 1, 2017 (as such date may be extended due to Tenant Delays and a maximum of (30) days of such Force Majeure delays), Landlord shall deliver possession of the Leased Premises “Substantially
Complete,” defined herein to mean (i) the Building shall have been substantially completed in accordance with the Final Base Building Plans (as defined in Paragraph 1 of the Work Letter) therefor and the City of Santa Clara shall have
signed off on the building 

  
 7 

 Building C 
  

permit for the Building, but for minor punch list items, (ii) all Building systems and subsystems described in Exhibit A-1 to the Work Letter, the structural elements of the Leased Premises
and the Building, and the foundation of the Building, are in good working order and repair, (iii) all improvements needed for the Building (excluding the Leased Premises) and the Common Areas to be in compliance with the Santa Clara Building
Code and the Americans With Disabilities Act have been completed, (iv) the number of parking spaces required by this Lease shall have been completed, (v) the Cafe & Fitness Center shall have been completed and Tenant and the
Tenant Parties shall have access thereto and use thereof (which Tenant hereby acknowledges has been completed), (vi) the elevators, stairwells, shared restrooms, ground floor lobby, and associated mechanical, engineering, and plumbing shall
have been substantially completed, and (vii) all scaffolding shall have been removed from the Building. Substantial Completion of the Building and Warm Shell Components (as defined in Paragraph 1 of the Work Letter) shall be deemed to have
occurred when the City has signed off on the final building permit. Tenant hereby acknowledges for purposes of this Lease (including but not limited to this Paragraph 2.4 and Paragraph 2.8 below) that the Leased Premises and the Warm Shell
Components (as defined in the Work Letter) and the Common Areas supporting the Building (as delineated in Paragraph 2.8 below) have been Substantially Completed prior to the Effective Date of this Lease, except only for the completion of the
Landlord’s Additional Work. 
 (d) If by four (4) months after the date set forth in Paragraph 2.4(c) above (as such date may be
extended any Tenant Delays and up to thirty (30) days of Force Majeure), Landlord shall not have delivered possession of the Leased Premises Substantially Complete, Tenant shall have the right to terminate this Lease by written notice to
Landlord delivered within ten (10) business days of such date (as extended if extended). 
 (e) Any Tenant Delay during the period
after the Delivery Date shall serve to extend the March 1, 2017 date set forth in Paragraph 2.4(c) above on a day-for-day basis. 
 (f)
Notwithstanding any other provision of this Lease or the Work Letter to the contrary, Tenant shall be responsible for payment of all utility charges reasonably attributable to the construction of the Tenant Improvements (and not the Landlord’s
Additional Work) relating to the period from the Delivery Date through the Lease Commencement Date, after which Paragraph 3.2 below shall govern. 

2.5 Performance Of Tenant Improvement Work; Acceptance Of Possession. Tenant shall, pursuant to the Work Letter, perform the work and
make the installations in the Leased Premises substantially as set forth in the Work Letter (such work and installations hereinafter referred to as the “Tenant Improvements”). Subject to the terms of Paragraph 2.8 below, it is
agreed that by accepting possession of the Substantially Complete Leased Premises, Tenant agrees that it will have accepted the same and acknowledged that the Leased Premises are in the condition called for under this Lease (including the Work
Letter). 
 2.6 Surrender Of Possession. Immediately prior to the expiration or upon the sooner termination of this Lease, Tenant
shall remove all of Tenant’s signs from the exterior of the Building and shall remove all of Tenant’s equipment (including telecommunications wiring and cabling), trade fixtures, furniture, supplies, wall decorations and other personal
property from within the Leased Premises, the Building and the Common Areas, and shall vacate and surrender the Leased Premises, the Building, the Common Areas, the Property, and the Project to Landlord in the same condition, broom clean, as existed
at the Lease Commencement Date, reasonable wear and tear and damage caused by Landlord or Landlord’s employees, agents, contractors, or subcontractors (collectively with Landlord, the “Landlord Parties”) and casualty not caused
by Tenant or Tenant Parties, excepted. Tenant shall repair all damage to the Leased Premises, the exterior of the Building and the Common Areas caused by Tenant’s removal of Tenant’s property. Tenant shall patch and refinish, to
Landlord’s reasonable satisfaction, all penetrations made by Tenant or its employees to the floor, walls or ceiling of the Leased Premises, whether such penetrations were made with Landlord’s approval or not. Tenant shall repair or replace
all stained or damaged ceiling tiles, wall coverings and floor coverings to the reasonable satisfaction of Landlord. Subject to the terms of Paragraph 9.3 below, Tenant shall repair all damage caused by Tenant to the exterior surface of the Building
and the Exclusive Use Common Areas and, where necessary, replace or resurface same. Additionally, to the extent that Landlord shall have notified or is deemed to have notified Tenant in writing at the time the applicable improvements were consented
to, that it desired to have certain Non-Standard Office Improvements made by or at the request of Tenant removed at the expiration or sooner termination of this Lease, Tenant shall, upon the expiration or sooner termination of this Lease:
(A) remove such Non-Standard Office Improvements constructed or installed by Landlord or Tenant (including any backup generator or other mechanical equipment), but only if they had been identified as Non-Standard Office Improvements by Landlord
at the time consented to pursuant to Paragraph 6.1 below or the Work Letter, as applicable, and (B) repair all damage caused by such removal. If the Leased Premises, the Building, and the Exclusive Use Common Areas are not surrendered to
Landlord in the condition required by this paragraph at the expiration or sooner termination of this Lease, Landlord may, at Tenant’s expense, so remove Tenant’s signs, property and/or improvements not so 

  
 8 

 Building C 
  

removed and make such repairs and replacements not so made or hire, at Tenant’s expense, independent contractors to perform such work. Tenant shall be liable to Landlord for all costs
incurred by Landlord in returning the Leased Premises, the Building and the Exclusive Use Common Areas to the required condition, together with interest on all costs so incurred from the date paid by Landlord at the Default Interest Rate until paid.
Tenant shall pay to Landlord the amount of all costs so incurred plus such interest thereon, within thirty (30) days of Landlord’s billing Tenant for same. Tenant shall not be required to remove its initial Tenant Improvements constructed
pursuant to and in accordance with the Work Letter, except to the extent they constitute “Non-Standard Office Improvements,” defined herein to mean alterations, modifications, and improvements that (i) affect the Building
façade or structure, (ii) are other than typical leasehold improvements for office tenants in the Building or in buildings similar to the Building in the area in which the Property is located, or (iii) in Landlord’s reasonable
judgment would materially increase Landlord’s cost of preparing the Leased Premises for another tenant (such as, without limitation, interior staircases). As further illustration of items that may or may not be considered Non-Standard Office
Improvements: (1) Tenant improvements of a type or quantity that would not be installed by or for a typical tenant using space for general office or research and development purposes, such as internal stairwells or high density mobile filing
systems, auditoriums, movie theaters or film projection rooms, private restrooms, data center rooms, swimming pools, basketball courts, laboratories and, supplemental HVAC units or ducting would be considered Non-Standard Office Improvements; and
(2) “open ceilings”, kitchens, lunch rooms, cafés, break rooms, small, non-specialized server rooms, and expanded restroom areas built by Tenant would be considered Non-Standard Office Improvements. 

2.7 Accessibility. In accordance with California Civil Code section 1938, Landlord hereby informs Tenant that as of the Effective Date
of this Lease, neither the Leased Premises nor the Building have been inspected by a Certified Access Specialist (as defined in California Civil Code section 55.52(3)). 

2.8 Condition Upon Substantial Completion. Landlord hereby warrants that the Warm Shell Components (as defined in the Work Letter) and
the Common Areas supporting the Building, consisting of (i) a minimum of 3.3 parking spaces for each 1,000 net rentable square feet of Leased Premises located within the area depicted by a curved dotted line on Schedule 2.2(a) attached
to this Lease, (ii) such sidewalks or paths as are necessary to allow Tenant access from the parking areas to the Building, and (iii) the landscaping in front of the Building (defined for purposes of this Lease as the “Building
Specific Common Areas”) shall be in good working condition as of the date of Substantial Completion thereof (the “Substantial Completion Date”). In the event that Tenant believes, and Tenant notifies Landlord in writing
within twelve (12) months after the Substantial Completion Date, that the Warm Shell Components or Building Specific Common Areas were not in good working condition and repair on the Substantial Completion Date, then unless Landlord disagrees,
Landlord shall, at Landlord’s sole cost and expense (which shall not be deemed a Property Maintenance Cost), repair or replace any failed or inoperable portion of such Warm Shell Components or Building Specific Common Areas, as applicable
(“Landlord’s Warranty”), provided that the need to repair or replace was not caused by the misuse, misconduct, damage, destruction, acts, omissions, and/or negligence (collectively, “Tenant Damage”) of Tenant
or any Tenant Parties, or by any modifications, alterations, or improvements (including the Tenant Improvements) constructed by or on behalf of Tenant. Landlord’s Warranty shall not be deemed to require Landlord to replace any portion of any
Warm Shell Components or Building Specific Common Areas, as applicable, as opposed to repair such portion of such Warm Shell Components or Building Specific Common Areas, as applicable, unless prudent commercial property management practices dictate
replacement rather than repair of the item in question. To the extent repairs which Landlord is required to make pursuant to this Paragraph 2.8 are necessitated in part by Tenant Damage and not fully covered by Landlord’s insurance, then Tenant
shall reimburse Landlord for an equitable proportion of the cost of such repair. If it is determined that the Warm Shell Components or Building Specific Common Areas (or any portion thereof) were not in good working condition and repair as of the
Substantial Completion Date, Landlord shall not be liable to Tenant for any damages, but Landlord, at no cost to Tenant, shall promptly commence such work or take such other action as may be necessary to place the same in good working condition and
repair, and shall thereafter diligently pursue the same to completion; and Landlord shall repair any damage to the Tenant Improvements arising in connection with Landlord’s work. Tenant’s failure to give such written notice to Landlord
within twelve (12) months after the Substantial Completion Date shall constitute a conclusive presumption that the Warm Shell Components (or Building Specific Common Areas, as applicable) are in good working condition and repair, and any required
correction after that date shall be performed by the party responsible for such repair pursuant to the terms of this Lease; provided, however, the foregoing shall not constitute a waiver by Tenant or a release of Landlord with respect to
Landlord’s obligations under this Lease relating to the construction of the Building and the Project. In the event that Tenant notifies Landlord in writing within twelve (12) months after the Substantial Completion Date, that the Warm
Shell Components or Building Specific Common Areas were not in good working condition and repair on the Substantial Completion Date, and Landlord disagrees, then Landlord and Tenant shall meet and confer in good faith to try to reach agreement
within thirty (30) days, failing which the matter shall be referred to arbitration before a single arbitrator at JAMS in San Francisco. 

  
 9 

 Building C 
  

ARTICLE 3 
 RENT 

3.1 Base Monthly Rent.  

(a) Commencing on the Lease Commencement Date (as determined pursuant to Paragraph 2.3 above) and continuing throughout the Lease Term, Tenant
shall pay to Landlord, without prior demand therefor, in advance on the first day of each calendar month, cash or other immediately available good funds in the amount set forth as Base Monthly Rent in Article 1. 

(b) Base Monthly Rent is not payable during the first nine (9) months of the Lease Term (the “Rent Abatement Period”).
Notwithstanding anything to the contrary contained in this Lease, Landlord shall have the option (the “Lump Sum Payment Option”) to require Tenant to pay Base Monthly Rent for so much of the Rent Abatement Period as remains
following Landlord’s notice as hereinafter provided at the rate of $101,850.90 per month, beginning on the date (the “Base Monthly Rent Start Date”) set forth in the Lump Sum Payment Option Notice (defined below), which shall
in no event be a date prior to payment to Tenant of the Abated Rent Lump Sum Payment. To exercise the Lump Sum Payment Option, Landlord must (i) provide written notice to Tenant of such exercise (the “Lump Sum Payment Option
Notice”) and (ii) pay to Tenant the Base Monthly Rent that would be payable for the remaining Rent Abatement Period (the “Abated Rent Lump Sum Payment”). If Landlord elects its Lump Sum Payment Option, the Abated Rent
Lump Sum Payment shall be made, at Landlord’s election (a) within thirty (30) days of Tenant’s receipt of the Lump Sum Payment Option Notice, or (b) on the closing date of any financing or sale of the Building by Landlord
(the date of such payment is hereinafter referred to as the “Lump Sum Payment Date”). If Landlord fails to pay the Abated Rent Lump Sum Payment by the Lump Sum Payment Date or the financing or sale transaction for the Building, if
applicable, expires or is terminated or deemed null and void for any reason, Landlord’s exercise of the Lump Sum Payment Option shall be deemed null and void and of no further force or effect and the Abated Rent Lump Sum Payment, if theretofore
paid by Landlord to Tenant, shall promptly be returned by Tenant to Landlord. If Landlord’s Lump Sum Payment Notice is effective on a day other than the first day of a calendar month and Landlord has then paid the Abated Rent Lump Sum Payment,
then Tenant shall pay any Base Monthly Rent payable hereunder for the period from Landlord’s Lump Sum Payment Option Notice through the last day of the calendar month, with the next installment of Base Monthly Rent due for the following
calendar month. 
 (c) If Landlord exercises its Lump Sum Payment Option in accordance with the above paragraph, Landlord shall prepare an
amendment in the form of Exhibit G attached hereto (the “Lump Sum Payment Amendment”) that documents the effect of Landlord’s exercise of the Lump Sum Payment Option and sets forth a revised rent schedule reflecting
Tenant’s payment of the Base Monthly Rent for the remaining Rent Abatement Period following the Lump Sum Payment Option Notice. A copy of the Lump Sum Payment Amendment shall be sent to Tenant and Tenant shall execute and return the Lump Sum
Payment Amendment to Landlord within ten (10) business days thereafter, but Landlord’s otherwise valid exercise of the Lump Sum Payment Option shall be fully effective whether or not the Lump Sum Payment Amendment is executed. 

3.2 Additional Rent. Commencing on the Lease Commencement Date (as determined pursuant to Paragraph 2.3 above) and continuing
throughout the Lease Term, in addition to the Base Monthly Rent and to the extent not required by Landlord to be contracted for and paid directly by Tenant, Tenant shall pay to Landlord as additional rent (the “Additional Rent”),
cash or other immediately available good funds in the following amounts: 
 (a) An amount equal to all Property Operating Expenses (as
defined in Article 13) incurred or to be incurred by Landlord. Landlord shall deliver to Tenant Landlord’s reasonable estimate of any given expense (such as Landlord’s Insurance Costs or Real Property Taxes), or group of expenses, which it
anticipates will be paid or incurred for the ensuing calendar or fiscal year, as Landlord may determine, and Tenant shall pay to Landlord an amount equal to Tenant’s Building Share or Tenant’s Project Share, as applicable, of the estimated
amount of such expenses for such year in equal monthly installments during such year with the installments of Base Monthly Rent. Landlord reserves the right to revise such estimate from time to time but not more than once during the applicable year
and, in any event shall provide Tenant with at least one (1) month advance notice of such adjusted estimates taking effect. 
 (b)
Landlord’s share of the consideration received by Tenant upon certain assignments and sublettings as required by Article 7. 
 (c)
Any legal fees and costs that Tenant is obligated to pay or reimburse to Landlord pursuant to Article 13; and 

  
 10 

 Building C 
  

(d) Any other charges or reimbursements due Landlord from Tenant pursuant to the terms of this Lease. 

Notwithstanding the foregoing, at any time that Tenant leases all of the rentable square footage in the Building, Landlord may elect by written notice to
Tenant to have Tenant pay Real Property Taxes or any portion thereof directly to the applicable taxing authority, in which case Tenant shall make such payments and deliver satisfactory evidence of payment to Landlord no later than ten (10) days
before such Real Property Taxes become delinquent. In the event Tenant is responsible to pay taxes directly, Landlord shall have no obligation to make such payments, whether or not Landlord receives evidence of payment from Tenant, and Tenant shall
in all cases be responsible for any fines, penalties, interest and damages for late payment. 
 3.3 Year-End Adjustments.
Landlord shall furnish to Tenant within four months following the end of the applicable calendar or fiscal year, as the case may be, a statement setting forth (i) the amount of such expenses paid or incurred during the just ended calendar or
fiscal year, as appropriate, and (ii) the amount that Tenant has paid to Landlord for credit against such expenses for such period. If Tenant shall have paid more than its obligation for such expenses for the stated period, Landlord shall, at
its election, either (i) credit the amount of such overpayment toward the next ensuing payment or payments of Additional Rent that would otherwise be due or (ii) refund in cash to Tenant the amount of such overpayment within thirty
(30) days after discovery of such surplus; provided, however, that if this Lease shall have terminated, Landlord shall be deemed to have chosen option (ii) above. If such year-end statement shall show that Tenant did not pay its obligation
for such expenses in full, then Tenant shall pay to Landlord the amount of such underpayment within thirty (30) days from Landlord’s billing of same to Tenant. Tenant may, at Tenant’s sole cost and expense, cause an audit of
Landlord’s books and records to determine the accuracy of Landlord’s billings for Property Operating Expenses under this Lease, provided Tenant completes (and delivers to Landlord the written results of) such audit within two hundred
seventy (270) days after Tenant’s receipt of the year-end statement described above setting forth the annual reconciliation of the Property Operating Expenses, and provided further that the person or entity performing such audit is not
compensated on any type of contingent basis. If such audit reveals that the actual Property Operating Expenses for any given year were less than the amount that Tenant paid for Property Operating Expenses for any such year, then unless Landlord
contests such audit results as provided below, Landlord shall credit the excess to Tenant’s next payment of Additional Rent. If such audit reveals that the actual Property Operating Expenses for any given year were more than the amount that
Tenant paid for Property Operating Expenses for any such year, Tenant shall pay such amount to Landlord within thirty (30) days after completion of the audit. Landlord shall have the right to contest the results of Tenant’s audit and
thereafter promptly have an audit performed (“Landlord’s Audit”) by a certified public accounting firm acceptable to Landlord and Tenant in their reasonable discretion. In such case, the results of Landlord’s Audit shall
be binding and conclusive on Landlord and Tenant, and any resulting overpayment or underpayment shall be handled as provided above. If Landlord’s Audit, or Tenant’s audit in the event Landlord does not elect to have Landlord’s Audit
performed, confirms that Tenant was overcharged by more than five percent (5%), then Landlord shall pay the cost of Tenant’s audit (up to a maximum of $7,500) and Landlord’s Audit. If Tenant’s audit confirms that Tenant was not
overcharged, then Tenant shall pay the cost of Landlord’s Audit (up to a maximum of $7,500) and Tenant’s audit. In all other cases, each party shall pay for its own audit. The provisions of this Paragraph shall survive the expiration or
sooner termination of this Lease. 
 3.4 Late Charge, And Interest On Rent In Default. Tenant acknowledges that the late payment by
Tenant of any monthly installment of Base Monthly Rent or any Additional Rent will cause Landlord to incur certain costs and expenses not contemplated under this Lease, the exact amounts of which are extremely difficult or impractical to fix. Such
costs and expenses will include without limitation, administration and collection costs and processing and accounting expenses. Therefore, if any installment of Base Monthly Rent is not received by Landlord from Tenant within five (5) calendar
days after the same becomes due, Tenant shall immediately pay to Landlord a late charge in an amount equal to the amount set forth in Article 1 as the “Late Charge Amount,” and if any Additional Rent is not received by Landlord when
the same becomes due, Tenant shall immediately pay to Landlord a late charge in an amount equal to 5% of the Additional Rent not so paid; provided, however, that once but only once in any twelve (12) month period during the Lease Term, Tenant
shall be entitled to written notice of non-receipt of Base Monthly Rent or Additional Rent from Landlord, and Tenant shall not be liable for any Late Charge Amount or other late charge hereunder with respect thereto if such installment of Base
Monthly Rent or Additional Rent is received by Landlord within three (3) business days after Tenant’s receipt of such written notice from Landlord. Landlord and Tenant agree that this late charge represents a reasonable estimate of such
costs and expenses and is fair compensation to Landlord for the anticipated loss Landlord would suffer by reason of Tenant’s failure to make timely payment. In no event shall this provision for a late charge be deemed to grant to Tenant a grace
period or extension of time within which to pay any rental installment or prevent Landlord from exercising any right or remedy available to Landlord upon Tenant’s failure to pay each rental installment due under this Lease when due, including
the right to terminate this Lease. If any rent remains delinquent for a period in excess of five (5) calendar days, then, in addition to such late charge, Tenant shall pay to Landlord interest on any rent that is not so paid from said fifth (5th) day at the Default Interest Rate until paid. 

  
 11 

 Building C 
  

3.5 Payment Of Rent. Except as specifically provided otherwise in this Lease, all rent shall be paid in lawful money of the United
States, without any abatement, reduction or offset for any reason whatsoever, to Landlord at such address as Landlord may designate from time to time at least thirty (30) days in advance of the date the next payment of rent is due.
Tenant’s obligation to pay Base Monthly Rent and all Additional Rent shall be appropriately prorated at the commencement and expiration of the Lease Term. The failure by Tenant to pay any Additional Rent as required pursuant to this Lease when
due shall be treated the same as a failure by Tenant to pay Base Monthly Rent when due, and Landlord shall have the same rights and remedies against Tenant as Landlord would have had Tenant failed to pay the Base Monthly Rent when due. 

ARTICLE 4 
 USE OF LEASED
PREMISES AND COMMON AREA 
 4.1 Permitted Use. Tenant shall be entitled to use the Leased Premises on a 24/7/365 basis solely for
the Permitted Use as set forth in Article 1 and for no other purpose whatsoever. Tenant shall have the right to vacate the Leased Premises at any time during the Term of this Lease, provided Tenant maintains the Leased Premises in the same condition
as if fully occupied and as otherwise required by the terms of this Lease. Tenant shall have the right to use the Common Areas in conjunction with its Permitted Use of the Leased Premises solely for the purposes for which they were designed and
intended and for no other purposes whatsoever.  
 4.2 General Limitations On Use. Tenant shall not do or permit anything to
be done in or about the Leased Premises, the Building, the Common Areas, the Property, or the Project which does or could (i) jeopardize the structural integrity of the Building or (ii) cause damage to any part of the Leased Premises, the
Building, the Common Areas, the Property, or the Project. Tenant shall not operate any equipment within the Leased Premises which does or could (A) injure, vibrate or shake the Leased Premises or the Building, (B) damage, overload or
impair the efficient operation of any electrical, plumbing, and HVAC systems within or servicing the Leased Premises or the Building, or (C) damage or impair the efficient operation of the sprinkler system (if any) within or servicing the
Leased Premises or the Building. Tenant shall not install any equipment or antennas on or make any penetrations of the exterior walls or roof of the Building, except to the extent specifically set forth in the Tenant Improvement Working Drawings
approved by Landlord pursuant to Paragraph 2 of the Work Letter or as otherwise provided in Paragraph 4.14 below. Tenant shall not affix any equipment to or make any penetrations or cuts in the floor, ceiling, walls or roof of the Leased Premises
except to the extent specifically set forth in the Tenant Improvement Working Drawings approved by Landlord pursuant to Paragraph 2 of the Work Letter or any alterations to the Leased Premises approved by Landlord pursuant to Paragraph 6.1 below.
Tenant shall not place any loads upon the floors, walls, ceiling or roof systems which could endanger the structural integrity of the Building or damage its floors, foundations or supporting structural components. Tenant shall not place any
explosive, flammable or harmful fluids or other waste materials in the drainage systems of the Leased Premises, the Building, the Common Areas, the Property, or the Project. Tenant shall not drain or discharge any fluids in the landscaped areas or
across the paved areas of the Property or the Project. Tenant shall not use any of the Common Areas for the storage of its materials, supplies, inventory or equipment and all such materials, supplies, inventory or equipment shall at all times be
stored within the Leased Premises. Tenant shall not commit nor permit to be committed by any of its employees, agents, vendors, invitees, guests, permittees, assignees, sublessees, contractors, or subcontractors (the “Tenant
Parties”), any physical waste in or about the Leased Premises, the Building, the Common Areas, the Property, or the Project.  

4.3 Noise And Emissions. All noise generated by Tenant in its use of the Leased Premises shall be confined or muffled so that it does
not interfere with the businesses of or annoy the occupants and/or users of adjacent properties. All dust, fumes, odors and other emissions generated by Tenant’s use of the Leased Premises shall be sufficiently dissipated in accordance with
sound environmental practice and exhausted from the Leased Premises in such a manner so as not to interfere with the businesses of or annoy the occupants and/or users of adjacent properties, or cause any damage to the Leased Premises, the Building,
the Common Areas, the Property, or the Project or any component part thereof or the property of adjacent property owners.  
 4.4
Trash Disposal. Landlord shall provide trash bins or other adequate garbage disposal facilities within the trash enclosure areas provided or permitted by Landlord outside the Leased Premises sufficient for the interim disposal of all of its
trash, garbage and waste. All such trash, garbage and waste temporarily stored in such areas by Tenant or any of the Tenant Parties shall be stored in such a manner so that it is not visible from outside of such areas. Landlord shall cause such
trash, garbage and waste to be regularly removed from the trash bins/garbage disposal facilities and the Property. Subject to the foregoing removal obligation of Landlord, Tenant shall keep the interior of the Leased Premises in a clean, safe and
neat condition and shall keep the Common Areas free and clear of all of Tenant’s trash, garbage, waste and/or boxes, pallets and containers containing same at all times. 

 

  
 12 

 Building C 
  

4.5 Parking. Tenant shall not, at any time, park or permit to be parked any recreational vehicles, inoperative vehicles or equipment in
the Common Areas or on any portion of the Project. Tenant agrees to assume responsibility for compliance by its employees and invitees with the parking provisions contained herein. If Tenant or its employees park any vehicle within the Property or
the Project in violation of these provisions, then Landlord may, upon prior written notice to Tenant giving Tenant two (2) days (or any applicable statutory notice period, if longer than two (2) days) to remove such vehicle(s), cause the same
to be removed at Tenant’s expense. Tenant agrees to assume responsibility for compliance by the Tenant Parties with the parking provisions contained herein. Landlord reserves the right to grant easements and access rights to others for use of
the parking areas on the Property and/or Project, provided that the Required Conditions are satisfied. Tenant shall have the right to install electric vehicle charging stations (“ECV Stations”) on the Property in a location
acceptable to Landlord in its reasonable discretion, all at Tenant’s sole cost, including but not limited to the cost of running conduit; provided, however, that Tenant may (within sixty (60) days after the Effective Date of this Lease,
if at all) request Landlord to provide conduit to up to such number of Tenant’s Exclusive Parking Spaces as Tenant shall request, from the Building electrical room, in which case Landlord shall provide such conduit at Landlord’s sole cost.
Further, Tenant may (within sixty (60) days after the Effective Date of this Lease, if at all) request Landlord to provide conduit to up to such number of Tenant’s Additional Exclusive Parking Spaces as Tenant shall request, from the
Building electrical room, in which case Landlord shall provide such conduit at Tenant’s sole cost (which may be paid out of the Tenant Improvement Allowance). 

4.6 Signs. Tenant shall not place or install on or within any portion of the Leased Premises, the exterior of the Building, the Common
Areas, the Property, or the Project any sign, advertisement, banner, placard, or picture which is visible from the exterior of the Leased Premises, except as expressly allowed pursuant to this Paragraph 4.6. Subject to the other terms and conditions
of this Paragraph 4.6, Tenant, at Tenant’s sole cost and expense, shall: (i) have the right to install its name on the lobby directory sign, (ii) be entitled to place its name on the Building top in the location generally as depicted
on Exhibit H, and (iii) be entitled to place its name on the Building monument sign generally as depicted on Exhibit H, in all cases in accordance with Landlord’s Building signage program and to the extent approved by the
City of Santa Clara. The size, location, and configuration of all signage shall be subject to Landlord’s building standards and its prior written approval, which shall not be unreasonably withheld, and shall be governed by and subject to the
rules, regulations and permit requirements of the City of Santa Clara. All of the foregoing rights set forth in this paragraph shall be personal to Aruba Networks, Inc., or a sublessee of more than 50% of the initial Leased Premises, or an assignee,
and no other party shall have any such right. Except as provided above, Tenant shall not place or install on or within any portion of the Leased Premises, the exterior of the Building, the Common Areas, the Property, or the Project any business
identification sign which is visible from the exterior of the Leased Premises until Landlord shall have approved in writing and in its sole discretion the location, size, content, design, method of attachment and material to be used in the making of
such sign; provided, however, that so long as such signs are normal and customary business directional or identification signs within the Building, Tenant shall not be required to obtain Landlord’s approval. Any sign, once approved by
Landlord, shall be installed at Tenant’s sole cost and expense and only in strict compliance with Landlord’s approval and any applicable Laws and Restrictions, using a person approved by Landlord to install same. Landlord may remove any
signs (which have not been approved in writing by Landlord), advertisements, banners, placards or pictures so placed by Tenant on or within the Leased Premises, the exterior of the Building, the Common Areas, the Property, or the Project and charge
to Tenant the cost of such removal, together with any costs incurred by Landlord to repair any damage caused thereby, including any cost incurred to restore the surface (upon which such sign was so affixed) to its original condition. Tenant shall
remove all of Tenant’s signs, repair any damage caused thereby, and restore the surface upon which the sign was affixed to its original condition, all to Landlord’s reasonable satisfaction, upon the termination of this Lease.
Notwithstanding the signage rights granted to Tenant pursuant to this Paragraph 4.6, Landlord reserves and retains the right to place Landlord’s name and/or ownership affiliation in or on the Leased Premises, the Building, the Common Areas, the
Property, or the Project, or on any of the signs located thereon, as determined in Landlord’s sole discretion. 
 4.7 Compliance
With Laws And Restrictions. Subject to Paragraph 6.3 below, Tenant shall abide by and shall promptly observe and comply with, at its sole cost and expense, all Laws and Restrictions respecting the use and occupancy of the Leased Premises, the
Building, the Common Areas, the Property, or the Project including, without limitation, Title 24, building codes, the Americans with Disabilities Act and the rules and regulations promulgated thereunder, and all Laws governing the use and/or
disposal of hazardous materials, and shall defend with competent counsel, indemnify and hold Landlord harmless from any claims, damages or liability resulting from Tenant’s failure to so abide, observe, or comply. Tenant’s obligations
hereunder shall survive the expiration or sooner termination of this Lease. 

  
 13 

 Building C 
  

4.8 Compliance With Insurance Requirements. With respect to any insurance policies required or permitted to be carried by Landlord in
accordance with the provisions of this Lease, Tenant shall not conduct nor permit any other person to conduct any activities nor keep, store or use (or allow any other person to keep, store or use) any item or thing within the Leased Premises, the
Building, the Common Areas, the Property, or the Project which (i) is prohibited under the terms of any such policies, (ii) could result in the termination of the coverage afforded under any of such policies, (iii) could give to the
insurance carrier the right to cancel any of such policies, or (iv) could cause an increase in the rates (over standard rates) charged for the coverage afforded under any of such policies. Tenant shall comply with all requirements of any
insurance company, insurance underwriter, or Board of Fire Underwriters which are necessary to maintain, at standard rates, the insurance coverages carried by either Landlord or Tenant pursuant to this Lease. 

4.9 Landlord’s Right To Enter. Landlord and its agents shall have the right to enter the Leased Premises during normal business
hours after giving Tenant reasonable notice (which shall be prior written notice except in the event of a circumstance which Landlord in good faith believes to be an emergency) and subject to Tenant’s reasonable security measures for the
purpose of (i) inspecting the same; (ii) showing the Leased Premises to prospective purchasers, mortgagees or, during the last nine (9) months of the Lease Term or during any period that Tenant is in monetary or material non-monetary
default beyond the applicable cure period, if any, expressly set forth in this Lease, tenants; (iii) making necessary alterations, additions or repairs; and (iv) performing any of Tenant’s obligations when Tenant has failed to do so
after the expiration of any applicable notice and cure period expressly set forth in this Lease. Landlord shall have the right to enter the Leased Premises during normal business hours (or as otherwise agreed), subject to Tenant’s reasonable
security measures, for purposes of supplying any maintenance or services agreed to be supplied by Landlord. Landlord shall have the right to enter the Common Areas during normal business hours for purposes of (i) inspecting the exterior of the
Building and the Common Areas; (ii) posting notices of nonresponsibility (and for such purposes Tenant shall provide Landlord at least ten (10) days’ prior written notice of any work to be performed on the Leased Premises, as well as
notice within one (1) day after the commencement of such work); and (iii) supplying any services to be provided by Landlord. Landlord shall also have the right, upon reasonable advance notice to Tenant, to access the Building’s
vertical risers and the interstitial space above Tenant’s acoustical ceiling to connect new utility and communications lines from other floors to the base Building utility lines; all of such work shall be done after hours or on weekends. Any
entry into the Leased Premises or the Common Areas obtained by Landlord in accordance with this paragraph shall not under any circumstances be construed or deemed to be a forcible or unlawful entry into, or a detainer of, the Leased Premises, or an
eviction, actual or constructive of Tenant from the Leased Premises or any portion thereof. Landlord shall conduct all of Landlord’s activities on the Leased Premises during such period of entry in a manner designed to cause minimal
interference to Tenant and Tenant’s use of the Leased Premises. 
 4.10 Use Of Common Areas. Tenant, in its use of the Common
Areas, shall at all times keep the Common Areas clear of Tenant’s and the Tenant Parties’ materials, equipment, debris, trash (except within existing enclosed trash areas), inoperable vehicles, and other items which are not specifically
permitted by Landlord to be stored or located thereon by Tenant. If, in the opinion of Landlord, unauthorized persons are using any of the Common Areas by reason of, or under claim of, the express or implied authority or consent of Tenant, then
Tenant, upon demand of Landlord, shall restrain, to the fullest extent then allowed by Law, such unauthorized use, and shall initiate such appropriate proceedings as may be required to so restrain such use. Landlord reserves the right to grant
easements and access rights to others for use of the Common Areas so long as the Required Conditions are satisfied, and shall not be liable to Tenant for any diminution in Tenant’s right to use the Common Areas as a result. 

4.11 Environmental Protection. Tenant’s obligations under this Paragraph 4.11 shall survive the expiration or termination of this
Lease. 
 (a) As used herein, the term “Hazardous Materials” shall mean any toxic or hazardous substance, material or waste
or any pollutant or infectious or radioactive material, including but not limited to those substances, materials or wastes regulated now or in the future under any of the following statutes or regulations and any and all of those substances included
within the definitions of “hazardous substances,” “hazardous materials,” “hazardous waste,” “hazardous chemical substance or mixture,” “imminently hazardous chemical substance or mixture,”
“toxic substances,” “hazardous air pollutant,” “toxic pollutant,” or “solid waste” in the (a) Comprehensive Environmental Response, Compensation and Liability Act of 1990 (“CERCLA” or
“Superfund”), as amended by the Superfund Amendments and Reauthorization Act of 1986 (“SARA”), 42 U.S.C. § 9601 et seq., (b) Resource Conservation and Recovery Act of 1976 (“RCRA”), 42 U.S.C. §
6901 et seq., (c) Federal Water Pollution Control Act (“FSPCA”), 33 U.S.C. § 1251 et seq., (d) Clean Air Act (“CAA”), 42 U.S.C. § 7401 et seq., (e) Toxic Substances Control Act
(“TSCA”), 14 U.S.C. § 2601 et seq., (f) Hazardous Materials Transportation Act, 49 U.S.C. § 1801, et seq., (g) Carpenter-Presley-Tanner Hazardous Substance Account Act (“California Superfund”),
Cal. Health & Safety Code § 25300 et seq., (h) California 

  
 14 

 Building C 
  

Hazardous Waste Control Act, Cal. Health & Safety code § 25100 et seq., (i) Porter-Cologne Water Quality Control Act
(“Porter-Cologne Act”), Cal. Water Code § 13000 et seq., (j) Hazardous Waste Disposal Land Use Law, Cal. Health & Safety codes § 25220 et seq., (k) Safe Drinking Water and Toxic Enforcement
Act of 1986 (“Proposition 65”), Cal. Health & Safety code § 25249.5 et seq., (l) Hazardous Substances Underground Storage Tank Law, Cal. Health & Safety code § 25280 et seq., (m) Air
Resources Law, Cal. Health & Safety Code § 39000 et seq., and (n) regulations promulgated pursuant to said laws or any replacement thereof, or as similar terms are defined in the federal, state and local laws, statutes,
regulations, orders or rules. Hazardous Materials shall also mean any and all other biohazardous wastes and substances, materials and wastes which are, or in the future become, regulated under applicable Laws for the protection of health or the
environment, or which are classified as hazardous or toxic substances, materials or wastes, pollutants or contaminants, as defined, listed or regulated by any federal, state or local law, regulation or order or by common law decision, including,
without limitation, (i) trichloroethylene, tetrachloroethylene, perchloroethylene and other chlorinated solvents, (ii) any petroleum products or fractions thereof, (iii) asbestos, (iv) polychlorinated biphenyls, (v) flammable
explosives, (vi) urea formaldehyde, (vii) radioactive materials and waste, and (viii) materials and wastes that are harmful to or may threaten human health, ecology or the environment. 

(b) Notwithstanding anything to the contrary in this Lease, Tenant, at its sole cost, shall comply with, and shall cause the Tenant Parties to
comply with, all Laws relating to the storage, use and disposal of Hazardous Materials at the Property; provided, however, that Tenant shall not be responsible for contamination of the Leased Premises and/or the Building, the Property, or the
Project (including the Parking Structure) by Hazardous Materials existing as of the date the Leased Premises are delivered to Tenant (whether before or after the Lease Commencement Date) excepting only contamination caused by Tenant or the Tenant
Parties. Tenant shall not store, use or dispose of any Hazardous Materials except for ordinary office and cleaning supplies used in compliance with all Laws and Restrictions (“Office & Cleaning Supplies”). In no event shall
Tenant cause, or permit to be discharged by any of the Tenant Parties, into the plumbing or sewage system of the Building or onto the land underlying or adjacent to the Building, any Hazardous Materials. Tenant shall be solely responsible for and
shall defend, indemnify, and hold Landlord and its agents harmless from and against all claims, costs and liabilities, including reasonable attorneys’ fees and costs, arising out of or in connection with Tenant’s storage, use and/or
disposal of Hazardous Materials at the Project. If the presence of Hazardous Materials on the Leased Premises caused by Tenant or any of the Tenant Parties results in contamination or deterioration of water or soil, then Tenant shall promptly take
any and all action necessary to clean up such contamination, but the foregoing shall in no event be deemed to constitute permission by Landlord to allow the presence of such Hazardous Materials. At any time prior to the expiration of the Lease Term
if Tenant has a reasonable basis to suspect that there has been any release or the presence of Hazardous Materials in the ground or ground water on the Leased Premises which did not exist upon commencement of the Lease Term, Tenant shall have the
right to conduct appropriate tests of water and soil and to deliver to Landlord the results of such tests to demonstrate that no contamination in excess of permitted levels has occurred as a result of Tenant’s use of the Leased Premises. Tenant
shall further be solely responsible for, and shall defend, indemnify, and hold Landlord and its agents harmless from and against all claims, costs and liabilities, including attorneys’ fees and costs, arising out of or in connection with any
removal, cleanup and restoration work and materials required hereunder to return the Leased Premises and any other property of whatever nature to their condition existing prior to the appearance of the Hazardous Materials, to the extent such
Hazardous Materials were introduced to the Property or the Project by Tenant or any of the Tenant Parties. 
 (c) Upon termination or
expiration of the Lease Term, Tenant at its sole expense shall cause all Hazardous Materials placed in or about the Leased Premises, the Building and/or the Property by Tenant or any of the Tenant Parties, and all installations (whether interior or
exterior) made by or on behalf of Tenant or any of the Tenant Parties relating to the storage, use, disposal or transportation of Hazardous Materials to be removed from the property and transported for use, storage or disposal in accordance and
compliance with all Laws and other requirements respecting Hazardous Materials used or permitted to be used by Tenant. If Tenant uses any Hazardous Materials other than Office & Cleaning Supplies, then Tenant shall apply for and shall
obtain from all appropriate regulatory authorities (including any applicable fire department or regional water quality control board) all permits, approvals and clearances necessary for the closure of the Property and the Project and shall take all
other actions as may be required to complete the closure of the Building, the Property, and the Project. 
 (d) At any time prior to
expiration of the Lease Term, subject to reasonable prior notice (not less than forty-eight (48) hours) and Tenant’s reasonable security requirements and provided such activities do not unreasonably interfere with the conduct of
Tenant’s business at the Leased Premises, Landlord shall have the right to enter in and upon the Property, Building and Leased Premises in order to conduct appropriate tests of water and soil to determine whether levels of any Hazardous
Materials in excess of legally permissible levels has occurred as a result of Tenant’s use thereof. Landlord shall furnish copies of all such test results and reports to Tenant and, at Tenant’s option and cost, shall permit split sampling
for testing and analysis by Tenant. Such testing shall be at Tenant’s expense if Landlord has a reasonable basis for suspecting and confirms the presence of Hazardous 

  
 15 

 Building C 
  

Materials in the soil or surface or ground water in, on, under, or about the Property, the Building or the Leased Premises, which has been caused by or resulted from the activities of Tenant or
any of the Tenant Parties. 
 (e) Landlord may voluntarily cooperate in a reasonable manner with the efforts of all governmental agencies in
reducing actual or potential environmental damage. Tenant shall not be entitled to terminate this Lease or to any reduction in or abatement of rent by reason of such voluntary cooperation, nor for any required compliance. Tenant agrees at all times
to cooperate fully with the requirements and recommendations of governmental agencies regulating, or otherwise involved in, the protection of the environment, provided that Tenant is not required to incur any liability or more than de minimus
expense in connection therewith. 
 4.12 Rules And Regulations. Landlord shall have the right from time to time to establish
reasonable and non-discriminatory rules and regulations and/or amendments or additions thereto respecting the use of the Building and the Common Areas for the care and orderly management of the Property. No rules and regulations shall require Tenant
to pay rent nor shall any such rules and regulations apply retroactively. Upon delivery to Tenant of a copy of such rules and regulations or any amendments or additions thereto, Tenant shall comply with such rules and regulations. A violation by
Tenant of any of such rules and regulations shall constitute a default by Tenant under this Lease. If there is a conflict between the rules and regulations and any of the provisions of this Lease, the provisions of this Lease shall prevail. Landlord
shall not be responsible or liable to Tenant for the violation of such rules and regulations by any other tenant of the Property. 
 4.13
Reservations. Landlord reserves the right from time to time to grant, without the consent or joinder of Tenant, such easements, rights of way and dedications that Landlord deems necessary, and to cause the recordation of parcel maps and
restrictions, so long as such easements, rights of way and dedications do not unreasonably interfere with the use of the Leased Premises by Tenant and the Required Conditions are satisfied. Tenant agrees to execute any documents reasonably requested
by Landlord to effectuate any such easement rights, dedications, maps or restrictions. 
 4.14 Roof. Subject to Paragraph 2.1 above,
notwithstanding any provision of this Lease to the contrary, Landlord hereby reserves to itself and its other tenants in the Project all rights of access, use and occupancy of the Building roof, and Tenant shall have no right of access, use or
occupancy of the Building roof except (if at all) to the extent provided in this Paragraph 4.14. Landlord will designate a portion of the roof to hold a rooftop equipment pad (a “Roof Pad”) for installations by tenants of the
Building (the “Available Rooftop Space”). Tenant shall be entitled to utilize Tenant’s Building Share of the Available Rooftop Space as follows: 

(a) Subject to Tenant’s restoration and repair obligations under Paragraph 2.6, Tenant at its sole cost and expense shall have the right
to install within Tenant’s Building Share of the Available Rooftop Space, mechanical and electrical equipment and satellite dishes, television antennas, and related cable connections (collectively, “Rooftop Equipment”) required
in connection with Tenant’s own business and communications and data transmission network, in an area to be reasonably agreed upon by Landlord and Tenant in the Available Rooftop Space, provided such installation does not impact the structural
integrity of the Building, is not inconsistent with the Project aesthetics, and does not void or negatively impact any applicable warranties. 

(b) Tenant shall supply Landlord with detailed plans and specifications of the Rooftop Equipment prior to the installation thereof for
Landlord’s review and approval. Furthermore, Tenant shall have secured Landlord’s approval and the approval of all governmental authorities and all permits required by governmental authorities having jurisdiction over such approvals and
permits for the Rooftop Equipment, and shall provide copies of such approvals and permits to Landlord prior to commencing any work with respect to such Rooftop Equipment. Tenant shall pay for any and all costs and expenses in connection with, and
shall repair all damage to the roof resulting from, the installation, maintenance, use and removal of the Rooftop Equipment. 
 Landlord will reasonably
cooperate with Tenant (at Tenant’s expense) to: (i) expand the Roof Pad or add a second Roof Pad to accommodate Tenant’s additional supplemental equipment, and/or (ii) locate an equipment pad on the ground in close proximity to
Building; provided however, if all or a portion of such equipment pad is located in the parking areas, then the number of parking spaces lost by virtue of the equipment pad shall nonetheless be counted toward the total number of parking spaces to
which Tenant is entitled pursuant to this Lease. 
 4.15 Back-Up Generator. Subject to complying with Paragraphs 2.6 and 6.1, Tenant
shall have the right to install a backup generator and certain other mechanical equipment in the Available Rooftop Space or in another location mutually agreed to by the parties, subject to Landlord’s approval in its sole but good faith
discretion, of its design (including aesthetic screening) and construction, and of any connections between the Leased Premises and such generator and any penetrations to the Building walls, 

  
 16 

 Building C 
  

roof, or structure required in connection therewith. If such backup generator or other mechanical equipment is located on any parking areas on the Project, then such lost parking spaces shall be
counted towards satisfying Tenant’s parking allocation under Article 1 hereof. 
 ARTICLE 5 

REPAIRS, MAINTENANCE, SERVICES AND UTILITIES 

5.1 Repair And Maintenance. Except in the case of damage to or destruction of the Leased Premises, the Building, the Common Areas, the
Property, or the Project caused by an act of God or other peril, in which case the provisions of Article 10 shall control, the parties shall have the following obligations and responsibilities with respect to the repair and maintenance of the Leased
Premises, the Building, the Common Areas,, the Property, and the Project. 
 (a) Tenant’s Obligations. Tenant shall, at all
times during the Lease Term and at its sole cost and expense, regularly clean and continuously keep and maintain in good order, condition and repair the interior, non-structural portions of the Leased Premises and every part thereof, including,
without limiting the generality of the foregoing, (i) all interior walls, floors and ceilings, (ii) all interior windows, doors and skylights, (iii) all electrical wiring, conduits, connectors and fixtures within the Leased Premises,
(iv) all interior sinks, toilets, and faucets and, to the extent serving just the Leased Premises, plumbing, pipes, and drains, (v) all interior lighting fixtures, bulbs and lamps, (vi) any back-up generator(s), HVAC equipment, or
other equipment installed by or at the request of Tenant, (vii) all entranceways to the Leased Premises with respect to which Tenant and the Tenant Parties have exclusive access rights, and (viii) the Building elevator(s) during any period
that Tenant is leasing the entire rentable square footage of the Building; provided, however, that Tenant shall not be required to maintain, repair, and replace those items which are Landlord’s obligation to maintain, repair, and replace
pursuant to Paragraph 5.1(b) below. Tenant shall, at Tenant’s sole cost and expense, provide for its own janitorial service for the Leased Premises. Subject to Paragraph 9.3 below, Tenant shall, at its sole cost and expense, repair all damage
to the Leased Premises, the Building, the Common Areas, the Property, or the Project caused by the activities of Tenant or any of the Tenant Parties promptly following written notice from Landlord to so repair such damages. If Tenant shall fail to
perform the required maintenance or fail to make repairs required of it pursuant to this paragraph within the notice and cure periods specified in Paragraph 12.1(b) below, then Landlord may, at its election and without waiving any other remedy it
may otherwise have under this Lease or at law, perform such maintenance or make such repairs and charge to Tenant, as Additional Rent, the costs so incurred by Landlord for same. All interior glass within or a part of the Leased Premises is at the
sole risk of Tenant and any broken glass shall promptly be replaced by Tenant at Tenant’s expense with glass of the same kind, size and quality. 

(b) Landlord’s Obligation. Landlord shall, at all times during the Lease Term, maintain in good condition and repair the Common
Areas, the foundation, slabs, roof structure and membrane, curtain walls and load-bearing and exterior walls of the Building, and (i) HVAC equipment (except as described in clause (vi) of Paragraph 5.1(a) above), and (ii) plumbing,
pipes, and drains, to the extent the items described in clauses (i) and (ii), serve both the Leased Premises and other portions of the Property. Landlord may hire a licensed HVAC contractor to regularly and periodically inspect and perform
required maintenance on the HVAC equipment and systems serving the Leased Premises and/or the Building. Landlord may also hire a licensed roofing contractor to regularly and periodically inspect and perform required maintenance on the roof of the
Building. Landlord shall keep the Common Areas in a clean condition. Landlord shall regularly and periodically sweep and clean the driveways and parking areas. Unless necessitated by the acts or omissions of Tenant or any of the Tenant Parties
(subject to the terms of Paragraph 9.3 below), Landlord shall make any necessary (x) structural repairs or structural replacements to the Leased Premises and (y) repairs or replacements to (i) any fire alarm and communication system
in the Leased Premises installed by Landlord, (ii) the electrical, plumbing, and mechanical portions of the Warm Shell Components as defined in the Work Letter), (iii) the Building elevator(s) except during any period that Tenant is
leasing the entire rentable square footage of the Building, and (iv) any sprinkler system installed by Landlord in the Leased Premises; if any of the foregoing are necessitated by the acts or negligent or wrongful omissions of Tenant or any of
the Tenant Parties (subject to Paragraph 9.3 below), Tenant shall reimburse to Landlord, within thirty (30) days after receipt of the applicable invoices, the cost incurred by Landlord in connection therewith. The provisions of this
subparagraph (b) shall in no way limit the right of Landlord to charge to Tenant, as Additional Rent pursuant to Article 3, the costs incurred by Landlord in performing such maintenance and/or inspections, and/or in making such repairs or
replacements; provided, however, that (1) Tenant shall not be responsible for any capital repairs or replacements costing over $10,000 individually, which are incurred by Landlord during the initial, unextended Lease Term, except to the
extent such capital repairs or replacements are necessitated by Tenant’s breach of this Lease), and (2) with respect to capital repairs or replacements costing less than $10,000 individually during the initial, unextended Lease Term,
Tenant shall pay the full amount thereof until in any twelve (12) month period Tenant has paid $50,000 on such capital repairs or replacements, and thereafter for the balance of such twelve (12) month period, Landlord shall pay for such
capital repairs or replacements and the cost incurred by Landlord, including interest at a rate equal to the Standard Interest Rate, shall be amortized by Landlord over the useful life of such capital 

  
 17 

 Building C 
  

repairs or replacements, as determined in accordance with generally accepted accounting principles, and the monthly amortized cost of such capital repairs or replacements as so amortized shall be
considered a Property Maintenance Cost. The entire foregoing proviso shall expire and be of no further force or effect after the initial unextended Lease Term has expired (i.e., it shall not be applicable during any extension periods). 

5.2 Utilities. 
 (a)
Landlord has arranged at its sole cost and expense and in its own name, for the supply of gas, water, and electricity to the Building, but shall not have responsibility for the delivery same to Tenant. Landlord is currently working with Silicon
Valley Power Company (“SVP”) to upgrade the Building transformer to provide 4,000 amps based upon Tenant requiring twenty-five (25) watts per rentable square foot of electrical power for Tenant’s ground floor electrical
servers and the other equipment Tenant intends to utilize in the Leased Premises. The final size of the transformer upgrade will be determined by SVP based upon its assessment of Tenant’s needs, and Landlord shall at its sole cost expense pay
the cost of such upgrade up to the foregoing 4,000 amps, and if applicable, Tenant shall pay for the cost to upgrade beyond 4,000 amps. Tenant shall, at its sole expense, install all 24-hour HVAC units, chillers, other such equipment, related
ducting, and other items as are required in order to properly service Tenant’s ground floor equipment and to separately meter the ground floor equipment electrical use, including Tenant’s above standard HVAC. Tenant shall connect all
Tenant-installed ground floor improvements solely to Tenant’s separate meter and shall contract directly with SVP for electrical supply to the ground floor equipment and related HVAC. Tenant shall not use the Building HVAC for any of
Tenant’s ground floor equipment. Tenant shall be responsible for determining if the local supplier of water, gas and electricity can supply the needs of Tenant and whether or not the existing water, gas and electrical distribution systems
within the Building and the Leased Premises are adequate for Tenant’s needs. Tenant shall be responsible for determining if the existing sanitary and storm sewer systems now servicing the Leased Premises and the Property are adequate for
Tenant’s needs. Tenant shall pay all charges for water, gas, electricity and storm and sanitary sewer services as so supplied to the Leased Premises, irrespective of whether or not the services are maintained in Landlord’s or Tenant’s
name. 
 (b) Landlord has installed or shall, at its sole expense, install sub-meters and connect them to the Building energy management
system to monitor Tenant’s electric use (other than that which Tenant is required to separately meter and contract for directly pursuant to Paragraph 5.2(a) above). Upon Tenant’s request either (x) via the energy management system
serving the Leased Premises, or (y) during Building Standard Hours, by 10:00 a.m. on any day for after-hours usage on that same day, and by 10:00 a.m. on Friday for after-hours usage on weekends or holidays, and subject to the payment
obligations described below, Landlord agrees to make HVAC available to Tenant outside of Building Standard Hours for Tenant’s typical office use. 

(c) Tenant shall pay: (i) for all of its consumption of electricity, gas and water within the Leased Premises, either directly pursuant
to Paragraph 5.2(a) above or as reasonably determined by Landlord based on the data from the sub-meter for electricity, and on a pro rata basis for gas and water service; and (ii) subject to Paragraph 5.2(d) below, (A) Tenant’s
Building Share of all Building utilities relating to HVAC, elevators, and Common Areas within the Building consumed during Building Standard Hours, and (B) Landlord’s reasonable estimate of the actual cost (including depreciation over the
useful life of the item in question) for all of such utilities described in clause (ii)(A) consumed by Tenant outside of Building Standard Hours as reasonably determined by Landlord based on the number of tenants utilizing such utilities, the
relative square footages of their respective leased premises, and the duration of their use. In no event shall the cost charged to Tenant for utilities used after Building Standard Hours include any profit or mark-up to Landlord. There shall be no
minimum number of hours required in charging Tenant such cost for utilities used after Building Standard Hours. Costs of utilities payable to Landlord (as opposed to those costs payable by Tenant directly to SVP) shall be paid by Tenant within
twenty (20) days after invoice therefor from time to time, or, at Landlord’s option, with respect to utility costs other than after hours HVAC and submetered electricity, shall be included in Property Maintenance Costs or, with respect to
the portion of electricity use that is submetered, shall be paid in estimated monthly installments subject to annual reconciliation in like fashion as for Property Maintenance Costs. 

(d) The costs to be paid by Tenant to Landlord Paragraph 5.2(c) above (as opposed to directly pursuant to Paragraph 5.2(a) above) are based on
Tenant’s HVAC use being what is currently typical of office users for heating and cooling of generic office space, and on such use specifically excluding continuous, near continuous, or heavy use (“Above-Standard Use”) of the
HVAC. Any Above-Standard Use (e.g., uses such as network operations centers, server rooms, and data centers) will require dedicated HVAC and separately metered utilities. Notwithstanding any other provision of this Lease, Tenant, at its sole cost
and expense, and in accordance with Article 6 below, will contract for directly and cause to be installed any such dedicated HVAC equipment (including separate meters), and shall be solely responsible for all ongoing maintenance, service, repairs,
replacements, and utility charges related to such dedicated HVAC. 

  
 18 

 Building C 
  

5.3 Security. Tenant acknowledges that Landlord has not undertaken any duty whatsoever to provide security for the Leased Premises, the
Building, the Common Areas, the Property, or the Project and, accordingly, Landlord is not responsible for the security of same or the protection of Tenant’s property or any of the Tenant Parties from any cause whatsoever, including but not
limited to criminal and/or terrorist acts. To the extent Tenant determines that such security or protection services are advisable or necessary, Tenant shall arrange for and pay the costs of providing same. In the event Landlord in its sole and
absolute discretion agrees to provide any security services, whether it be guard service or access systems or otherwise, Landlord shall do so strictly as an accommodation to Tenant and Landlord shall have no liability whatsoever in connection
therewith, whether it be for failure to maintain the secure access system, or for failure of the guard service to provide adequate security, or otherwise. Without limitation, Paragraph 8.1 below is intended by Tenant and Landlord to apply to this
Paragraph 5.3. 
 5.4 Energy And Resource Consumption. 

(a) Energy Consumption Reduction Efforts. Tenant shall comply with the Building Energy Management System and Utility Metering
requirements set forth in the Work Letter. In addition, Landlord may voluntarily cooperate in a reasonable manner with the efforts of governmental agencies and/or utility suppliers in reducing energy or other resource consumption within the
Property. Tenant shall not be entitled to terminate this Lease or to any reduction in or abatement of rent by reason of such cooperation. Tenant agrees at all times to cooperate fully with Landlord and to abide by all reasonable rules established by
Landlord (i) in order to maximize the efficient operation of the electrical, and HVAC systems and all other energy or other resource consumption systems with the Property and the Project and/or (ii) in order to comply with the
recommendations of utility suppliers and governmental agencies regulating the consumption of energy and/or other resources. 
 (b) Tenant
Utility Usage Data Reporting. If Tenant is billed directly by a utility company with respect to Tenant’s electricity and natural gas/propane usage data at the Leased Premises, then, promptly following Landlord’s written request, Tenant
shall provide its monthly electricity and natural gas/propane usage data for the Leased Premises to Landlord for the period of time requested by Landlord (in electronic or paper format) or, at Landlord’s option, provide any written
authorization or other documentation required for Landlord to request information regarding Tenant’s electricity and natural gas/propane usage data with respect to the Leased Premises directly from the utility company. 

5.5 Limitation Of Landlord’s Liability. Landlord shall not be liable to Tenant for injury to Tenant or any of the Tenant Parties,
or damage to property of Tenant or any Tenant Parties, or loss of Tenant’s or any Tenant Parties’ business or profits, nor shall Tenant be entitled to terminate this Lease or to any reduction in or abatement of rent, except as provided for
below, by reason of (i) Landlord’s failure to provide security services or systems within the Property or the Project for the protection of the Leased Premises, the Building or the Common Areas, or the protection of Tenant’s property
or any of the Tenant Parties, or (ii) Landlord’s failure to perform any maintenance or repairs to the Leased Premises, the Building, the Common Areas, the Property, or the Project within the notice and cure periods set forth in Paragraph
12.3 below, or (iii) any failure, interruption, rationing or other curtailment in the supply of water, electric current, gas or other utility service to the Leased Premises, the Building, the Common Areas, the Property, or the Project from
whatever cause (other than Landlord’s active gross negligence or willful misconduct), or (iv) the unauthorized intrusion or entry into the Leased Premises by third parties (other than Landlord). Notwithstanding the foregoing, in the event
that Tenant is prevented from using, and does not use, the Leased Premises or any portion thereof as a result of a Trigger Event (as defined below), then Tenant shall give Landlord written notice thereof and if such Trigger Event continues for five
(5) consecutive business days (such period herein called the “Eligibility Period”), then Tenant’s Base Monthly Rent and Tenant’s obligation to pay Project Operating Expenses shall be abated or reduced, as the case may
be, after expiration of the Eligibility Period for such period of time that Tenant continues to be so prevented from using, and does not actually use, the Leased Premises or a portion thereof, in the proportion that the rentable area of the portion
of the Leased Premises that Tenant is prevented from using bears to the total rentable area of the Leased Premises. As used herein, the term “Trigger Event” means any of the following events: (1) any failure by Landlord to
provide Tenant with access to the Leased Premises or the Project that materially impacts or interrupts Tenant’s use of the Leased Premises, unless such failure is a result of any Laws or Restrictions, (2) Landlord’s failure to perform
Landlord’s repair and maintenance obligations hereunder if such failure continues beyond any applicable notice and cure period and (3) a disruption of utilities to the Leased Premises, and such disruption is caused solely by the
intentional acts, negligence or willful misconduct of Landlord or any of Landlord’s Parties. 
 ARTICLE 6 

ALTERATIONS AND IMPROVEMENTS 

6.1 By Tenant. This Paragraph 6.1 does not relate to the Tenant Improvements installed in accordance with and pursuant to the Work
Letter, but to alterations, modifications, and improvements made after the date the Tenant Improvements are substantially completed. Tenant shall not make any 

  
 19 

 Building C 
  

Non-Standard Office Improvements until Landlord shall have first approved, in writing, the plans and specifications therefor, which approval may be withheld in Landlord’s sole discretion as
to Non-Standard Office Improvements which affect the Building façade, structure, or systems, and otherwise such approval may be withheld in Landlord’s reasonable discretion. Landlord’s written approval shall, if applicable, also
contain Landlord’s election to require Tenant to remove the subject Non-Standard Office Improvements at the expiration or earlier termination of this Lease, in which event Tenant shall be obligated to do so. All modifications, alterations or
improvements shall be made, constructed or installed by Tenant at Tenant’s expense (including all permit fees and governmental charges related thereto), using a licensed contractor first approved by Landlord which approval shall not be
unreasonably withheld or delayed, in substantial compliance with the Landlord-approved plans and specifications therefor. All work undertaken by Tenant shall be done in accordance with all Laws and Restrictions and in a good and workmanlike manner
using new materials of good quality. Tenant shall not commence the making of any such modifications or alterations or the construction of any such improvements until (i) any and all required governmental approvals and permits shall have been
obtained, (ii) all requirements regarding insurance imposed by this Lease have been satisfied, (iii) Tenant shall have given Landlord at least five (5) business days prior written notice of its intention to commence such work so that
Landlord may post and file notices of non-responsibility, and (iv) if requested by Landlord, Tenant shall have obtained contingent liability and broad form builder’s risk insurance in an amount satisfactory to Landlord in its reasonable
discretion to cover any perils relating to the proposed work not covered by insurance carried by Tenant pursuant to Article 9. In no event shall Tenant make any modification, alterations or improvements whatsoever to the Common Areas (except the
Exclusive Use Common Areas). As used in this Article, the term “modifications, alterations and/or improvements” shall include, without limitation, the installation of additional electrical outlets, overhead lighting fixtures,
drains, sinks, partitions, doorways, or the like. Notwithstanding the foregoing, Tenant, without Landlord’s prior written consent, shall be permitted to make alterations to the Leased Premises which are not Non-Standard Office Improvements
provided that: (a) Tenant shall timely provide Landlord the notices required pursuant to Paragraph 4.9 above, (b) Tenant shall have secured the approval of all governmental authorities and all permits required by governmental authorities
having jurisdiction over such approvals and permits for such alterations, and shall provide copies of such approvals and permits to Landlord prior to commencing any work with respect to such alterations, and (c) Tenant shall notify Landlord in
writing within thirty (30) days of completion of the alteration and deliver to Landlord a set of the plans and specifications therefor, either “as built” or marked to show construction changes made. 

6.2 Ownership Of Improvements. All modifications, alterations and improvements made or added to the Leased Premises by Tenant (other
than Tenant’s inventory, equipment, movable furniture, wall decorations and trade fixtures) shall be deemed real property and a part of the Leased Premises, but shall remain the property of Tenant during the Lease Term (which includes any
extension(s) thereof pursuant to Article 15 below, if applicable). At the expiration or sooner termination of this Lease, all such modifications, alterations and improvements other than Tenant’s inventory, equipment, movable furniture, wall
decorations and trade fixtures, shall automatically become the property of Landlord and shall be surrendered to Landlord as part of the Leased Premises as required pursuant to Article 2, unless Landlord shall require Tenant to remove any of such
modifications, alterations or improvements which constitute Non-Standard Office Improvements in accordance with the provisions of Article 2, in which case Tenant shall so remove same. Landlord shall have no obligations to reimburse Tenant for all or
any portion of the cost or value of any such modifications, alterations or improvements so surrendered to Landlord. All modifications, alterations or improvements which are installed or constructed on or attached to the Leased Premises by Landlord
and/or at Landlord’s expense shall be deemed real property and a part of the Leased Premises and shall be property of Landlord; provided, however, that the Tenant Improvements (as defined in Paragraph 2 of the Work Letter) shall become
Landlord’s property only upon the expiration or earlier termination of the Lease Term. All lighting, plumbing, electrical, HVAC fixtures, partitioning, window coverings, wall coverings and floor coverings installed by Tenant shall be deemed
improvements to the Leased Premises and not trade fixtures of Tenant. 
 6.3 Alterations Required By Law.  

(a) Landlord at its sole cost shall make all modifications, alterations and improvements to the Building, the Property, or the Project, that
are required by any governmental authority at any time due to the base Building constructed by Landlord not having been in compliance with the Laws then applicable governing its construction. 

(b) Tenant at its sole cost shall make all modifications, alterations and improvements to the Leased Premises, the Building, the Common Areas,
the Property, or the Project that are required by any Law because of (i) Tenant’s particular use or occupancy of the Leased Premises, the Building, the Common Areas, the Property, or the Project (as opposed to the Permitted Use generally),
(ii) Tenant’s application for any permit or governmental approval, or (iii) Tenant’s making of any modifications, alterations or improvements to or within the Leased Premises. 

  
 20 

 Building C 
  

(c) If Landlord shall, at any time during the Lease Term, be required by any governmental authority or Law to make any modifications,
alterations or improvements to the Building, the Property, or the Project, the cost incurred by Landlord in making such modifications, alterations or improvements, including interest at a rate equal to the Standard Interest Rate shall be amortized
by Landlord over the useful life of such modifications, alterations or improvements, as determined in accordance with generally accepted accounting principles, and the monthly amortized cost of such modifications, alterations and improvements as so
amortized shall be considered a Property Maintenance Cost. For purposes of this paragraph 6.3(c) only, the useful life of the applicable modifications, alterations or improvements shall be a minimum of fifteen (15) years, and in no event shall
Tenant be required to pay more than $100,000 per year on account of any monthly amortization payments arising pursuant to this paragraph 6.3(c). 

6.4 Liens. Tenant shall keep the Property and the Project and every part thereof free from any lien, and shall pay when due all bills
arising out of any work performed, materials furnished, or obligations incurred by Tenant, its agents, employees or contractors relating to the Property. If any such claim of lien is recorded against Tenant’s interest in this Lease, the
Property or any part thereof, Tenant shall bond against, discharge or otherwise cause such lien to be entirely released within ten (10) days after the same has been recorded. Tenant’s failure to do so shall be conclusively deemed a
material default under the terms of this Lease. 
 ARTICLE 7 

ASSIGNMENT AND SUBLETTING BY TENANT 

7.1 By Tenant. Tenant shall not sublet the Leased Premises or any portion thereof or assign its interest in this Lease, or permit the
occupancy of the Premises by other than Tenant, whether voluntarily or by operation of Law, without Landlord’s prior written consent which shall not be unreasonably withheld and shall be given within the time periods set forth in Paragraph 7.3
below. Any attempted subletting or assignment, or occupancy of the Leased Premises by other than Tenant, without Landlord’s prior written consent, at Landlord’s election, shall constitute a default by Tenant under the terms of this Lease.
The acceptance of rent by Landlord from any person or entity other than Tenant, or the acceptance of rent by Landlord from Tenant with knowledge of a violation of the provisions of this paragraph, shall not be deemed to be a waiver by Landlord of
any provision of this Article or this Lease or to be a consent to any subletting by Tenant or any assignment of Tenant’s interest in this Lease. Without limiting the circumstances in which it may be reasonable for Landlord to withhold its
consent to an assignment or subletting, Landlord and Tenant acknowledge that it shall be reasonable for Landlord to withhold its consent in the following instances: 

(a) the proposed assignee or sublessee is a governmental agency; 

(b) in Landlord’s reasonable judgment, the use of the Leased Premises by the proposed assignee or sublessee would involve occupancy other
than for a Permitted Use, would entail any alterations which would lessen the value of the leasehold improvements in the Leased Premises, or would require increased services by Landlord; 

(c) the credit-worthiness of the proposed assignee does not meet the credit standards applied by Landlord, which standards shall take into
account the fact that Aruba Networks, Inc. continues to be liable for the obligations of the assignee under this Lease; 
 (d) the proposed
assignee or sublessee (or any of its affiliates) has been in material default under a lease, has been in litigation with a previous landlord, or in the ten (10) years prior to the assignment or sublease has filed for bankruptcy protection, has
been the subject of an involuntary bankruptcy, or has been adjudged insolvent; 
 (e) Landlord (or any of its affiliates) has experienced a
previous default by or is in litigation with the proposed assignee or sublessee (or any of their affiliates); 
 (f) in Landlord’s
reasonable judgment, the Leased Premises, or the relevant part thereof, will be used in a manner that will violate any negative covenant as to use contained in this Lease; 

(g) the use of the Leased Premises by the proposed assignee or sublessee will violate any Law or Restriction; 

(h) the proposed assignee or sublessee is a tenant at the Project and there is competing space available within the Project which is suitable
for the needs of such assignee or sublessee; 
 (i) the proposed assignment or sublease fails to include all of the terms and provisions
required to be included therein pursuant to this Article 7; 

  
 21 

 Building C 
  

(j) Tenant is in monetary or material non-monetary default of any obligation of Tenant under this Lease; or 

(k) in the case of a subletting of less than the entire Leased Premises, if the subletting would result in the division of the Leased Premises
into more than two subparcels or would require improvements to be made outside of the Leased Premises. 
 7.2 Merger, Reorganization, or
Sale of Assets.  
 (a) Subject to Paragraphs 7.2(b) and 7.9 below: Any dissolution, merger, consolidation or other reorganization
of Tenant, or the sale or other transfer in the aggregate over the Lease Term of a controlling percentage of the capital stock of or other equity interests in Tenant, or the sale or transfer of all or a substantial portion of the assets of Tenant,
shall be deemed a voluntary assignment of Tenant’s interest in this Lease. The phrase “controlling percentage” means the direct or indirect ownership of or right to vote (i) stock possessing more than fifty percent of the
total combined voting power of all classes of Tenant’s capital stock issued, outstanding and entitled to vote for the election of directors, or (ii) equity interests possessing the ability to direct the management of Tenant. If Tenant is a
partnership, a withdrawal or change, voluntary, involuntary or by operation of Law, of any general partner, or the dissolution of the partnership, shall be deemed a voluntary assignment of Tenant’s interest in this Lease. Upon Landlord’s
request from time to time, Tenant shall promptly provide Landlord with a statement certified by the Tenant’s chief executive officer or chief operating officer, which shall provide the following information: (i) the names of all of
Tenant’s shareholders and their ownership interests at the time thereof, provided Tenant’s shares are not publicly traded; (ii) the state in which Tenant is incorporated; (iii) the location of Tenant’s principal place of
business; (iv) information regarding a material change in the corporate structure of Tenant, including, without limitation, a merger or consolidation; and (v) any other information regarding Tenant’s ownership that Landlord reasonably
requests. In the event of an acquisition by one entity of the controlling percentage of the capital stock of Tenant where this Lease is not assigned to and assumed in full by such entity, it shall be a condition to Landlord’s consent to such
change in control that such entity acquiring the controlling percentage assume, as a primary obligor, all rights and obligations of Tenant under this Lease (and such entity shall execute all documents reasonably required to effectuate such
assumption). 
 (b) Notwithstanding subparagraph (a) above, over-the-counter stock market transactions shall not be deemed to be
assignments under this Lease. In addition, provided that the conditions described below in this sentence have been satisfied prior to or upon such assignment or subleasing, Tenant may, without Landlord’s prior written consent, sublet the Leased
Premises or assign this Lease to a “Permitted Transferee,” defined herein as (i) a subsidiary, affiliate, division, corporation or joint venture controlling, controlled by or under common control with Tenant, (ii) a
successor entity resulting from a merger, consolidation, or nonbankruptcy reorganization by Tenant, or (iii) a purchaser of substantially all of Tenant’s assets, provided in all cases (i), (ii) and (iii) that (A) the
successor entity, assignee, purchaser or subtenant has a net worth equal to or greater than those of Tenant prior to the Effective Date of this Lease and a liquid net worth sufficient for Tenant to continually perform its obligations under the
Lease, and assumes in writing for the benefit of Landlord, this Lease and all of Tenant’s obligations under this Lease, and (B) the entity with the greatest net worth involved directly or indirectly in the ownership and/or control of the
acquiring, merged, reorganized, or consolidated entity (hereafter, the “Assignee Affiliate”) shall have unconditionally assumed in writing or guaranteed for the benefit of Landlord, in a form acceptable to Landlord, this Lease and
all of Tenant’s obligations under this Lease. If any assignment or subleasing occurs without such an assumption and/or without Landlord’s consent as provided in Paragraph 7.1 above, Tenant shall be deemed for all purposes to be in material
default under this Lease and the Assignee Affiliate (and the successor entity, assignee, purchaser or subtenant) shall for all purposes be deemed to have unconditionally assumed in writing for the benefit of Landlord, this Lease and all of
Tenant’s obligations under this Lease. In all events, Tenant shall remain fully liable under this Lease. 
 7.3 Landlord’s
Election. Except as provided for in Paragraph 7.2 above and Paragraph 7.9 below, if Tenant shall desire to assign its interest under the Lease or to sublet the Leased Premises, Tenant must first notify Landlord, in writing, of its intent to so
assign or sublet, at least twenty (20) days in advance of taking any action with respect thereto. Once Tenant has identified a potential assignee or sublessee, Tenant shall notify Landlord, in writing, of its intent to so assign or sublet, at
least twenty (20) days in advance of the date it intends to so assign its interest in this Lease or sublet the Leased Premises but not sooner than one hundred eighty (180) days in advance of such date, specifying in detail the terms of
such proposed assignment or subletting, including the name of the proposed assignee or sublessee, the proposed assignee’s or sublessee’s intended use of the Leased Premises, current financial statements (including a balance sheet, income
statement and statement of cash flow, all prepared in accordance with generally accepted accounting principles; provided, however, that, if applicable with respect to a proposed sublessee, during any period that the proposed sublessee
actually does not prepare its financial statements in accordance with generally accepted accounting principles, then financial statements prepared and reviewed by a reputable, third-party, independent certified public accountant shall suffice) of
such 

  
 22 

 Building C 
  

proposed assignee or sublessee, the signed letter of intent or term sheet containing the material terms of such assignment or subletting, and such other information as Landlord may reasonably
request. Landlord shall have a period of ten (10) business days following receipt of such notice and the required information within which to do one of the following: (i) consent to such requested assignment or subletting subject to
Tenant’s compliance with the conditions set forth in Paragraph 7.4 below, or (ii) refuse to so consent to such requested assignment or subletting, provided that such consent shall not be unreasonably refused, or (iii) terminate this
Lease in the case of an assignment, or (in the case of a sublease for a term expiring less than six (6) months from the Lease Expiration Date and which would bring the total square footage subject to subleases to more than 50% of the Leased
Premises’ square footage), terminate this Lease as to the proposed sublease premises, such termination to be effective on the date specified in Tenant’s notice as the intended effective date of the assignment or subletting. During such ten
(10) business day period, Tenant covenants and agrees to supply to Landlord, upon request, all necessary or relevant information which Landlord may reasonably request respecting such proposed assignment or subletting and/or the proposed
assignee or sublessee. In the event of an election to terminate this Lease by Landlord under clause (iii) above, Landlord shall have the right to enter into a direct lease with the proposed assignee or sublessee without payment of any
consideration to Tenant. If Landlord fails to respond by the end of such ten (10) business day period to Tenant’s request for consent to any proposed Transfer, Tenant may send a second
(2nd) request to Landlord, which request must contain the following inscription, in 14 point font and bold faced lettering: “SECOND NOTICE DELIVERED PURSUANT TO PARAGRAPH 7.3 OF
LEASE—FAILURE TO TIMELY RESPOND WITHIN FIVE (5) BUSINESS DAYS SHALL RESULT IN DEEMED APPROVAL OF ASSIGNMENT OR SUBLEASE.” If Tenant sends such a second request, and Landlord fails to respond within five (5) business days
after its receipt of same, the proposed assignment or subletting shall be deemed approved. Notwithstanding anything herein to the contrary, if Landlord exercises Landlord’s right to terminate this Lease then Tenant may revoke Tenant’s
request to transfer this Lease or a portion of the Leased Premises and thus end Landlord’s termination right by providing Landlord with written notice thereof within five (5) business days after receipt of Landlord’s termination
notice. 
 7.4 Conditions To Landlord’s Consent. If Landlord elects to consent, or shall have been ordered to so consent by a
court of competent jurisdiction, to such requested assignment or subletting, such consent shall be expressly conditioned upon the occurrence of each of the conditions below set forth, and any purported assignment or subletting made or ordered prior
to the full and complete satisfaction of each of the following conditions shall be void and, at the election of Landlord, which election may be exercised at any time following such a purported assignment or subletting but prior to the satisfaction
of each of the stated conditions, shall constitute a material default by Tenant under this Lease until cured by satisfying in full each such condition by the assignee or sublessee. The conditions are as follows: 

(a) Landlord having approved in form and substance the assignment or sublease agreement and any ancillary documents, which approval shall not
be unreasonably withheld by Landlord if the requirements of this Article 7 are otherwise complied with. 
 (b) Each such sublessee or
assignee having agreed, in writing satisfactory to Landlord and its counsel and for the benefit of Landlord, to assume, to be bound by, and to perform the obligations of this Lease to be performed by Tenant which relate to space being subleased.

 (c) Tenant having fully and completely performed all of its obligations under the terms of this Lease through and including the date of
such assignment or subletting. 
 (d) Tenant having reimbursed to Landlord all reasonable costs and reasonable attorneys’ fees incurred
by Landlord in conjunction with the processing and documentation of any such requested subletting or assignment. Tenant shall be obligated to so reimburse Landlord whether or not such subletting or assignment is completed. 

(e) Tenant having delivered to Landlord a complete and fully-executed duplicate original of such sublease agreement or assignment agreement
(as applicable) and all related agreements. 
 (f) Tenant having paid, or having agreed in writing to pay as to future payments, to Landlord
fifty percent (50%) of all assignment consideration or excess rentals to be paid to Tenant or to any other on Tenant’s behalf or for Tenant’s benefit for such assignment or subletting as follows: 

(i) If Tenant assigns its interest under this Lease and if all or a portion of the consideration for such assignment is to be paid by the
assignee at the time of the assignment, that Tenant shall have paid to Landlord and Landlord shall have received an amount equal to fifty percent (50%) of the assignment consideration so paid or to be paid (whichever is the greater) at the time
of the assignment by the assignee; or 
 (ii) If Tenant assigns its interest under this Lease and if Tenant is to receive all or a portion
of the consideration for such assignment in future installments, that Tenant and Tenant’s 

  
 23 

 Building C 
  

assignee shall have entered into a written agreement with and for the benefit of Landlord satisfactory to Landlord and its counsel whereby Tenant and Tenant’s assignee jointly agree to pay
to Landlord an amount equal to fifty percent (50%) of all such future assignment consideration installments to be paid by such assignee as and when such assignment consideration is so paid; or 

(iii) If Tenant subleases the Leased Premises, that Tenant and Tenant’s sublessee shall have entered into a written agreement with and
for the benefit of Landlord satisfactory to Landlord and its counsel whereby Tenant and Tenant’s sublessee jointly agree to pay to Landlord fifty percent (50%) of all excess rentals to be paid by such sublessee. 

7.5 Assignment Consideration And Excess Rentals Defined. For purposes of this Article, including any amendment to this Article by way
of addendum or other writing: (i) the term “assignment consideration” shall mean all consideration to be paid by the assignee to Tenant or to any other party on Tenant’s behalf or for Tenant’s benefit as consideration
for such assignment, without deduction for any costs or expenses incurred by Tenant in connection with such assignment, except that Tenant may deduct third party, market rate leasing commissions and legal fees paid, and tenant improvement costs
incurred, in connection with the assignment, in which case the amount thereof may be deducted with the balance to be paid to Landlord, and (ii) the term “excess rentals” shall mean all consideration to be paid by the sublessee to
Tenant or to any other party on Tenant’s behalf or for Tenant’s benefit for the sublease of all or any part of the Leased Premises in excess of the rent due to Landlord under the terms of this Lease for the portion subleased for the same
period, without deduction for any costs or expenses incurred by Tenant in connection with such sublease, except that Tenant may deduct third party, market rate leasing commissions and legal fees paid, and tenant improvement costs incurred, in
connection with the sublease, in which case the amount thereof may be deducted with the balance to be paid to Landlord. Tenant agrees that the portion of any assignment consideration and/or excess rentals arising from any assignment or subletting by
Tenant which is to be paid to Landlord pursuant to this Article now is and shall then be the property of Landlord and not the property of Tenant. 

7.6 Payments. All payments required by this Article to be made to Landlord shall be made in cash in full as and when they become due.
At the time Tenant, Tenant’s assignee or sublessee makes each such payment to Landlord, Tenant or Tenant’s assignee or sublessee, as the case may be, shall deliver to Landlord an itemized statement in reasonable detail showing the method
by which the amount due Landlord was calculated and certified by the party making such payment as true and correct. 
 7.7 Good
Faith. The rights granted to Tenant by this Article are granted in consideration of Tenant’s express covenant, which Tenant hereby makes, that all pertinent allocations which are made by Tenant between the rental value of the Leased
Premises and the value of any of Tenant’s personal property which may be conveyed or leased (or services provided) generally concurrently with and which may reasonably be considered a part of the same transaction as the permitted assignment or
subletting shall be made fairly, honestly and in good faith. If Tenant shall breach this covenant, Landlord may immediately declare Tenant to be in default under the terms of this Lease and terminate this Lease and/or exercise any other rights and
remedies Landlord would have under the terms of this Lease in the case of a material default by Tenant under this Lease. 
 7.8 Effect Of
Landlord’s Consent. No subletting or assignment, even with the consent of Landlord, shall relieve Tenant of its personal and primary obligation to pay rent and to perform all of the other obligations to be performed by Tenant hereunder, and
Aruba Networks, Inc. hereby agrees as follows in connection with any assignment of this Lease: 
 (a) The liability of Aruba Networks, Inc.
under this Lease shall be primary, and in any right of action which shall accrue to Landlord under this Lease, Landlord may, at its option, proceed against Aruba Networks, Inc. without having commenced any action or obtained any judgment against an
assignee. Aruba Networks, Inc. further agrees that it may be joined in any action against an assignee in connection with the said obligations of assignee and recovery may be had against Aruba Networks, Inc. in any such action. Aruba Networks, Inc.
hereby expressly waives the benefits and defenses under California Civil Code Sections 2821, 2839, 2847, 2848, 2849 and 2855 to the fullest extent permitted by applicable law. 

(b) If an assignee is in default of its obligations under this Lease, Landlord may proceed against either Aruba Networks, Inc. or the
assignee, or both, or Landlord may enforce against Aruba Networks, Inc. or the assignee any rights that Landlord has under the Lease, in equity or under applicable law. If the Lease terminates due to an assignees default or bankruptcy or similar
debtor protection law, Landlord may enforce this Lease against Aruba Networks, Inc., even if Landlord would be unable to enforce it against the assignee. Aruba Networks, Inc. specifically agrees and understands that Landlord may proceed forthwith
and immediately against an assignee or against Aruba Networks, Inc. following any default by an assignee. Aruba Networks, Inc. hereby waives all benefits and defenses under California Civil Code Sections 2845, 2848, 2849 and 2850, including without
limitation: (i) the right to require Landlord to proceed against an assignee, proceed against or exhaust any security that 

  
 24 

 Building C 
  

Landlord holds from an assignee or pursue any other remedy in Landlord’s power; (ii) any defense to its obligations hereunder based on the termination or limitation of an
assignee’s liability; and (iii) all notices of the existence, creation, or incurring of new or additional obligations. Landlord shall have the right to enforce this Lease regardless of the release or discharge of an assignee by Landlord or
by operation of any law relating to protection of debtors, bankruptcy, assignments for the benefit of creditors, or insolvency. 
 (c) The
obligations of Aruba Networks, Inc. under this Lease shall remain in full force and effect and Aruba Networks, Inc. shall not be discharged or limited by any of the following events with respect to an assignee or Aruba Networks, Inc.:
(i) insolvency, bankruptcy, reorganization arrangement, adjustment, composition, assignment for the benefits of creditors, liquidation, winding up or dissolution (each a “Financial Proceeding”); of (ii) any merger, acquisition,
consolidation or change in entity structure, or any sale, lease, transfer, or other disposition of any entity’s assets, or any sale or other transfer of interests in the entity (each an “Event of Reorganization”); or (iii) any
sale, exchange, assignment, hypothecation or other transfer, in whole or in part, of Landlord’s interest in the Leased Premises or the Lease. Without limiting the foregoing, Aruba Networks, Inc. hereby expressly waives the benefits and defenses
under any statute or judicial decision (including but not limited to the case styled In Re Arden, 176 F. 3d 1226 (9th Cir. 1999)) that would otherwise (i.e., were it not for such waiver) permit Aruba Networks, Inc. to claim or obtain the benefit of
any so called “capped claim” available to an assignee in any Financial Proceeding. If all or any portion of the obligations guaranteed hereunder are paid or performed and all or any part of such payment or performance is avoided or
recovered, directly or indirectly, from Landlord as a preference, fraudulent transfer or otherwise, then Aruba Networks, Inc.’s obligations hereunder shall continue and remain in full force and effect as to any such avoided or recovered payment
or performance. 
 (d) The provisions of this Lease may be changed by agreement between Landlord and an assignee without the consent of or
notice to Aruba Networks, Inc. This Lease may be assigned by Landlord or an assignee, and the Leased Premises, or a portion thereof, may be sublet by an assignee, all in accordance with the provisions of this Lease, without the consent of or notice
to Aruba Networks, Inc. Aruba Networks, Inc. shall remain primarily liable for the performance of the Lease so assigned. Without limiting the generality of the foregoing, Aruba Networks, Inc. waives the rights and benefits of California Civil Code
Sections 2819 and 2820 with respect to any change to the Lease between Landlord and an assignee, and agrees that by doing so Aruba Networks, Inc.’s liability shall continue even if (i) Landlord and an assignee alter any Lease obligations,
or (ii) Aruba Networks, Inc.’s remedies or rights against an assignee are impaired or suspended without Aruba Networks, Inc.’s consent by such alteration of Lease obligations. 

Consent by Landlord to one or more assignments of Tenant’s interest in this Lease or to one or more sublettings of the Leased Premises shall not be
deemed to be a consent to any subsequent assignment or subletting. No subtenant shall have any right to assign its sublease or to further sublet any portion of the sublet premises or to permit any portion of the sublet premises to be used or
occupied by any other party. No sublease may be terminated or modified during any period that Tenant is in monetary or material non-monetary default under this Lease, without Landlord’s prior written consent. If Landlord shall have been ordered
by a court of competent jurisdiction to consent to a requested assignment or subletting, or such an assignment or subletting shall have been ordered by a court of competent jurisdiction over the objection of Landlord, such assignment or subletting
shall not be binding between the assignee (or sublessee) and Landlord until such time as all conditions set forth in Paragraph 7.4 above have been fully satisfied (to the extent not then satisfied) by the assignee or sublessee, including, without
limitation, the payment to Landlord of all agreed assignment considerations and/or excess rentals then due Landlord. 
 7.9 Permitted
Occupants. Notwithstanding any contrary provision of this Article 7, Tenant shall have the right, without the receipt of Landlord’s consent and without payment to Landlord of any amounts under Paragraph 7.5 above, to permit the occupancy of
up to ten thousand (10,000) rentable square feet of space in the Leased Premises, in the aggregate, to any individual(s) or entity (collectively, “Permitted Occupants”) that has an ongoing business relationship with Tenant
(other than the dual occupancy of the Leased Premises), which occupancy shall include the use of a corresponding interior support area and other portions of the Leased Premises and Common Areas (including the parking facilities and the
Cafe & Fitness Center) which shall be common to Tenant and the Permitted Occupants, on and subject to the following conditions: (i) each Permitted Occupant shall be of a character and reputation consistent with the quality of the
Building and the Project; (ii) no Permitted Occupant shall occupy a separately demised portion of the Leased Premises or which contains an entrance to such portion of the Leased Premises other than the primary entrance to the Leased Premises;
(iii) such occupancy shall not be a subterfuge by Tenant to avoid its obligations under this Lease or the restrictions on Transfers or allocation of excess Base Monthly Rent pursuant to this Article 7; (iv) Tenant shall not permit such use
by any entity or organization in a manner such that the density of use of any portion of the Leased Premises would materially and adversely increase the strain on the Building Systems beyond the manufacturer’s recommended specifications
therefor or would violate any Laws, including but not limited to fire codes; and (v) the Permitted Occupants shall obtain all permits and licenses required by Laws for occupying and use of the Leased Premises, if such permits and licenses are

  
 25 

 Building C 
  

needed in addition to those held by Tenant; (vi) the Permitted Occupants shall be subject to and subordinate to all of the terms and provisions of this Lease; and (vii) no such
occupancy shall relieve Tenant from any liability under this Lease. Each Permitted Occupant shall be deemed to be a Tenant Party. Tenant shall promptly supply Landlord with any documents or information reasonably requested by Landlord regarding the
identity of any such Permitted Occupants. Any occupancy permitted under this Paragraph 7.9 shall not be deemed a transfer under this Article 7. Notwithstanding the foregoing, no such occupancy shall relieve Tenant from any liability under this
Lease. 
 ARTICLE 8 

LIMITATION ON LANDLORD’S LIABILITY AND INDEMNITY 

8.1 Limitation On Landlord’s Liability And Release. Landlord shall not be liable to Tenant for, and Tenant hereby releases and
waives all claims and rights of recovery against Landlord and its partners, principals, members, managers, officers, agents, employees, lenders, attorneys, contractors, invitees, consultants, predecessors, successors and assigns (including without
limitation prior and subsequent owners of the Property or the Project or portions thereof) (collectively, the “Landlord Indemnitees”) from, any and all liability, whether in contract, tort or on any other basis, for any injury to or
any damage sustained by Tenant or any of the Tenant Parties, any damage to property of Tenant or any of the Tenant Parties, or any loss to business, loss of profits or other financial loss of Tenant or any of the Tenant Parties resulting from or
attributable to the condition of, the management of, the repair or maintenance of, the protection of, the supply of services or utilities to, the damage in or destruction of the Leased Premises, the Building, the Property, the Project, or the Common
Areas, including without limitation (i) the failure, interruption, rationing or other curtailment or cessation in the supply of electricity, water, gas or other utility service to the Property, the Building or the Leased Premises; (ii) the
vandalism or forcible entry into the Building or the Leased Premises; (iii) the penetration of water into or onto any portion of the Leased Premises; (iv) the failure to provide security and/or adequate lighting in or about the Property,
the Building or the Leased Premises, (v) the existence of any design or construction defects within the Property, the Building or the Leased Premises; (vi) the failure of any mechanical systems to function properly (such as the HVAC
systems); (vii) the blockage of access to any portion of the Property, the Building or the Leased Premises, except that Tenant does not so release Landlord from such liability to the extent such damage was proximately caused by Landlord’s
gross negligence, willful misconduct, or Landlord’s failure to perform an obligation expressly undertaken by Landlord pursuant to this Lease after the time period(s) set forth in Paragraph 12.3 below shall have lapsed following receipt of
written notice from Tenant to so perform such obligation. 
 8.2 Tenant’s Indemnification Of Landlord. Tenant shall defend with
competent counsel reasonably satisfactory to Landlord any claims made or legal actions filed or threatened against the Landlord Indemnitees with respect to the violation of any Law, or the death, bodily injury, personal injury, property damage, or
interference with contractual or property rights suffered by any third party occurring within the Leased Premises or resulting from the use or occupancy by Tenant or any of the Tenant Parties of the Leased Premises, the Building or the Common Areas,
or resulting from the activities of Tenant or any of the Tenant Parties in or about the Leased Premises, the Building, the Common Areas, the Property, or the Project, and Tenant shall indemnify and hold the Landlord Indemnitees harmless from any
loss liability, penalties, or expense whatsoever (including but not limited to reasonable attorneys’ fees and any loss attributable to vacant space which otherwise would have been leased, but for such activities) resulting therefrom, except to
the extent proximately caused by the negligence or willful misconduct of Landlord. This indemnity agreement shall survive the expiration or sooner termination of this Lease. 

8.3 Landlord’s Indemnification Of Tenant. Landlord shall indemnify and hold Tenant harmless from any loss liability, penalties, or
expense whatsoever (including but not limited to reasonable attorneys’ fees) resulting from the gross negligence or willful misconduct of Landlord at or with respect to the Property, except to the extent proximately caused by the negligence or
willful misconduct of Tenant. This indemnity agreement shall survive the expiration or sooner termination of this Lease. 
 ARTICLE 9

 INSURANCE 
 9.1
Tenant’s Insurance. Tenant shall maintain insurance complying with all of the following: 
 (a) Tenant shall procure, pay for and
keep in full force and effect, at all times during the Lease Term, the following: 
 (i) Commercial general liability insurance insuring
Tenant against liability for personal injury, bodily injury, death and damage to property occurring within the Leased Premises, or resulting from Tenant’s use or occupancy of the Leased Premises, the Building, the Common Areas, the Property, or
the Project, or resulting from Tenant’s activities in or about the Leased Premises, the 

  
 26 

 Building C 
  

Property, or the Project, with coverage in an amount equal to Tenant’s Required Liability Coverage (as set forth in Article 1), which insurance shall contain “blanket contractual
liability” and “broad form property damage” endorsements insuring Tenant’s performance of Tenant’s obligations to indemnify Landlord as contained in this Lease. 

(ii) Fire and property damage insurance in “special form” coverage insuring Tenant against loss from physical damage to
Tenant’s personal property, inventory, trade fixtures and improvements within the Leased Premises with coverage for the full actual replacement cost thereof; 

(iii) Business income/extra expense insurance sufficient to pay Base Monthly Rent and Additional Rent for a period of not less than twelve
(12) months; 
 (iv) [Reserved]; 

(v) [Reserved]; 
 (vi)
[Reserved]; 
 (vii) Workers’ compensation insurance (statutory coverage) with employer’s liability in amounts not less than
$1,000,000 insurance sufficient to comply with all laws; and 
 (viii) With respect to making of any alterations or modifications or the
construction of improvements or the like undertaken by Tenant, course of construction, commercial general liability, automobile liability and workers’ compensation (to be carried by Tenant’s contractor), in an amount and with coverage
reasonably satisfactory to Landlord. 
 (b) Each policy of liability insurance required to be carried by Tenant pursuant to this paragraph
or actually carried by Tenant with respect to the Leased Premises, the Property, or the Project: (i) shall, except with respect to insurance required by subparagraphs (a)(ii) and (a)(viii) above, name Landlord, and such Landlord affiliates as
are designated by Landlord, as additional insureds; (ii) [reserved]; (iii) shall be primary insurance providing that the insurer shall be liable for the full amount of the loss, up to and including the total amount of liability set forth
in the declaration of coverage, without the right of contribution from or prior payment by any other insurance coverage of Landlord; (iv) shall be carried with companies with Best’s ratings of at least A and XI; (v) shall provide that
such policy shall not be subject to cancellation, lapse or change except after at least thirty (30) days prior written notice to Landlord, and (vi) shall contain a so-called “severability” or “cross liability”
endorsement. Each policy of property insurance maintained by Tenant with respect to the Leased Premises, the Property, or the Project or any property therein (i) shall provide that such policy shall not be subject to cancellation except after
at least thirty (30) days prior written notice to Landlord and (ii) shall contain a waiver and/or a permission to waive by the insurer of any right of subrogation against Landlord, its partners, principals, members, managers, officers,
employees, agents and contractors, which might arise by reason of any payment under such policy or by reason of any act or omission of Landlord, its partners, principals, members, managers, officers, employees, agents and contractors. 

(c) Prior to the time Tenant or any of its contractors enters the Leased Premises, Tenant shall deliver to Landlord, with respect to each
policy of insurance required to be carried by Tenant pursuant to this Article, a certificate of the insurer certifying in form satisfactory to Landlord that a policy has been issued, premium paid, providing the coverage required by this Paragraph
and containing the provisions specified herein. With respect to each renewal or replacement of any such insurance, the requirements of this Paragraph must be complied with not less than thirty (30) days prior to the expiration or cancellation
of the policies being renewed or replaced. Landlord may, at any time and from time to time, inspect and/or copy any and all insurance policies required to be carried by Tenant pursuant to this Article. If Landlord’s Lender or insurance advisor
reasonably determines at any time that the amount of coverage set forth in Paragraph 9.1(a) for any policy of insurance Tenant is required to carry pursuant to this Article is not adequate, then Tenant shall increase the amount of coverage for such
insurance to such greater amount as Landlord’s Lender or insurance advisor reasonably deems adequate; provided, however, that Tenant shall not be required to increase such amount beyond (i) with respect to increases determined by
Landlord’s Lender, the amount(s) actually required by Landlord’s Lender, and (ii) with respect to increases determined by Landlord’s insurance advisor, the amount(s) then being required or carried by other prudent landlords in
the Santa Clara or Sunnyvale area. In the event Tenant does not maintain said insurance, Landlord may, in its sole discretion and without waiving any other remedies hereunder, send to Tenant written notice of such failure, and if such failure is not
remedied within ten (10) days after receipt of such notice, then Landlord may procure said insurance and Tenant shall pay to Landlord as additional rent the cost of said insurance plus a five percent (5%) administrative fee. 

9.2 Landlord’s Insurance. With respect to insurance maintained by Landlord: 

  
 27 

 Building C 
  

(a) Landlord shall maintain, as the minimum coverage required of it by this Lease, fire and property damage insurance in so-called special form
coverage insuring Landlord (and such others as Landlord may designate) against loss from physical damage to the Building with coverage of not less than one hundred percent (100%) of the full actual replacement cost thereof and against loss of
rents for a period of not less than six months. Such fire and property damage insurance, at Landlord’s election but without any requirements on Landlord’s behalf to do so, (i) may be written in so-called “all risk” form,
excluding only those perils commonly excluded from such coverage by Landlord’s then property damage insurer; (ii) may provide coverage for physical damage to the improvements so insured for up to the entire full actual replacement cost
thereof; (iii) may be endorsed to cover loss or damage caused by any additional perils against which Landlord may elect to insure, including earthquake and/or flood; and/or (iv) may provide coverage for loss of rents for a period of up to
twelve months. Landlord shall not be required to cause such insurance to cover any of Tenant’s personal property, inventory, and trade fixtures, or any modifications, alterations or improvements made or constructed by Tenant to or within the
Leased Premises. Landlord shall use commercially reasonable efforts to obtain such insurance at competitive rates. Any earthquake insurance carried by Landlord for the Building or the Project may be a blanket insurance coverage policy covering the
Project and other office buildings owned by Landlord or Landlord’s affiliates, and shall be a blanket policy during any period that Landlord is a Menlo Equities affiliate and such a blanket policy is more economical than an individual
earthquake policy. 
 (b) Landlord shall maintain commercial general liability insurance insuring Landlord (and such others as are
designated by Landlord) against liability for personal injury, bodily injury, death, and damage to property occurring in, on or about, or resulting from the use or occupancy of the Property, or any portion thereof, with combined single limit
coverage of at least Ten Million Dollars ($10,000,000). Landlord may carry such greater coverage as Landlord or Landlord’s Lender or insurance advisor may from time to time determine is reasonably necessary for the adequate protection of
Landlord, the Property, and the Project provided such insurance is commonly carried by owners of property similarly situated and operating under similar circumstances. 

(c) Landlord may maintain boiler and machinery insurance to limits sufficient to restore the Building. 

(d) Landlord may maintain any other insurance which in the opinion of its insurance advisor is prudent to carry under the given circumstances,
provided such insurance is commonly carried by owners of property similarly situated and operating under similar circumstances. 
 9.3
Mutual Waiver Of Subrogation. Landlord hereby releases Tenant, and Tenant hereby releases Landlord and its respective partners, principals, members, officers, agents, employees and servants, from any and all liability for loss, damage or injury
to the property of the other in or about the Leased Premises, the Property, or the Project which is caused by or results from a peril or event or happening which is covered by insurance actually carried and in force at the time of the loss by the
party sustaining such loss. 
 ARTICLE 10 

DAMAGE TO LEASED PREMISES 

10.1 Landlord’s Duty To Restore. If the Leased Premises, the Building or the Common Areas (including, without limitation, the
Cafe & Fitness Center) are damaged by any peril after the Effective Date of this Lease, Landlord shall restore the same, as and when required by this paragraph, unless this Lease is terminated by Landlord pursuant to Paragraph 10.3 or by
Tenant pursuant to Paragraph 10.4. If this Lease is not so terminated, then upon the issuance of all necessary governmental permits, Landlord shall commence and diligently prosecute to completion the restoration of the Leased Premises, the Building
or the Common Area, as the case may be, to the extent then allowed by law, to substantially the same condition in which it existed as of the Lease Commencement Date. Landlord’s obligation to restore shall be limited to the improvements
constructed by Landlord. Landlord shall have no obligation to restore any alterations, modifications or improvements made by Tenant to the Leased Premises or any of Tenant’s personal property, inventory or trade fixtures. Upon completion of the
restoration by Landlord, Tenant shall forthwith replace or fully repair all of the Tenant Improvements to like or similar conditions as existed at the time immediately prior to such damage or destruction. 

10.2 Insurance Proceeds. All insurance proceeds available from the fire and property damage insurance carried by Landlord shall be paid
to and become the property of Landlord. If this Lease is terminated pursuant to either Paragraph 10.3 or 10.4, all insurance proceeds available from insurance carried by Tenant which cover loss of Tenant’s Alterations shall be paid to and
become the property of Tenant. With respect to insurance proceeds payable under Tenant’s insurance policies for damage or destruction to the Tenant Improvements, Landlord and Tenant shall share such proceeds in accordance with their relative
contributions to the initial cost thereof. For example, if the Tenant Improvements were to cost a total of $130 per rentable square foot, and Landlord were to have contributed a total of $65 per rentable square foot on the Tenant Improvements, then
Landlord and Tenant would share such proceeds equally. The determination of Landlord’s property and Tenant’s property shall be made pursuant to Paragraph 6.2. 

  
 28 

 Building C 
  

10.3 Landlord’s Right To Terminate. Landlord shall have the option to terminate this Lease in the event any of the following
occurs, which option may be exercised only by delivery to Tenant of a written notice of election to terminate within thirty (30) days after the date of such damage or destruction: 

(a) The Building is damaged by any peril covered by valid and collectible insurance actually carried by Landlord and in force at the time of
such damage or destruction (or any insurance Landlord was required to carry pursuant to the terms of this Lease) to such an extent that the estimated cost to restore the Building exceeds the lesser of (i) the insurance proceeds available from
insurance actually carried by Landlord, or (ii) fifty percent of the then actual replacement cost thereof. Notwithstanding the foregoing, Tenant may override Landlord’s election to terminate the Lease pursuant to clause (i) above if
Tenant shall agree in writing within ten (10) days after receipt of Landlord’s notice electing to terminate this Lease to pay any costs of restoration to the extent such costs exceed the amount of any insurance proceeds received by
Landlord (the “Casualty Shortfall Amount”), in which event Landlord cannot terminate this Lease and must rebuild the areas affected by the Casualty; provided, however, that if Tenant exercises such election, Tenant shall enter into
an agreement with Landlord pursuant to which Tenant will covenant to deposit into an escrow or, to the extent required by any lender with a lien on the Leased Premises, with such lender the Casualty Shortfall Amount on terms and conditions
reasonably acceptable to Landlord. In addition, if Tenant elects to override Landlord’s election to terminate this Lease as provided above, Tenant shall execute and deliver to any such lender any documents reasonably required by such lender to
evidence Tenant’s intention to keep this Lease in full force and effect. 
 (b) The Building is damaged by an uninsured peril, which
peril Landlord was not required to, and did not, insure against pursuant to the provisions of Article 9 of this Lease. 
 (c) The Building
is damaged by any peril and, because of the Laws or Restrictions then in force, the Building, if restored, cannot be used for the same use being made thereof before such damage. 

Notwithstanding anything herein to the contrary, if the Leased Premises is not affected by the casualty in question, then Landlord may not terminate this
Lease unless it terminates the leases of all of the other tenants of the Building. 
 10.4 Tenant’s Right To Terminate. If the
Leased Premises, the Building or the Common Area are damaged by any peril and Landlord does not elect to terminate this Lease or is not entitled to terminate this Lease pursuant to this Article, then as soon as reasonably practicable, Landlord shall
furnish Tenant with the written opinion of Landlord’s architect or construction consultant as to when the restoration work required of Landlord may be complete. Landlord agrees to provide such opinion to Tenant within thirty (30) days
after the date of damage if reasonably practicable; otherwise, Landlord will provide a written status report to Tenant within such 30-day period and shall subsequently issue a final opinion to Tenant within ten (10) days of the date on which
Landlord determines the availability of permits to rebuild and the date on which Landlord determines the availability of insurance proceeds to rebuild, whichever is later. Will Tenant shall have the option to terminate this Lease (if Tenant is not
then in monetary or material non-monetary default) in the event any of the following occurs, which option may be exercised only by delivery to Landlord of a written notice of election to terminate within thirty (30) days after Tenant receives
from Landlord the estimate of the time needed to complete such restoration: 
 (a) If the time estimated to substantially complete the
restoration exceeds twelve months from and after the date the architect’s or construction consultant’s written opinion is delivered; or 

(b) If the damage occurred within eighteen months of the last day of the Lease Term and the time estimated to substantially complete the
restoration exceeds one hundred eighty (180) days from and after the date such restoration is commenced. 
 (c) In addition, if the
damage was not caused by the actions or omissions of Tenant or any of Tenant’s Parties, Tenant may terminate this Lease if the Leased Premises or any portions of the Common Area providing access to or parking for the Leased Premises are damaged
by a casualty to the extent that Tenant does not have reasonable access to or parking for the Leased Premises and Landlord has not within a reasonable time (not to exceed ninety (90) days from the date of the casualty) provided a reasonable
parking alternative for Tenant at the Project or in offsite areas within reasonable proximity to the Building and Tenant is not actually using the Leased Premises as a result thereof. 

10.5 Tenant’s Waiver. Landlord and Tenant agree that the provisions of Paragraph 10.4 above, captioned “Tenant’s Right
To Terminate”, are intended to supersede and replace the provisions 

  
 29 

 Building C 
  

contained in California Civil Code, Section 1932, Subdivision 2, and California Civil Code, Section 1933, and accordingly, Tenant hereby waives the provisions of such Civil Code
Sections and the provisions of any successor Civil Code Sections or similar laws hereinafter enacted. 
 10.6 Abatement Of Rent. In
the event of damage to the Leased Premises which does not result in the termination of this Lease, then the Base Monthly Rent (and any Additional Rent) shall be temporarily abated during the period of Landlord’s and/or Tenant’s (as
applicable) restoration, in proportion in the degree to which Tenant’s use of the Leased Premises during the restoration period is impaired by such damage. In addition, if such casualty shall have damaged the Building or any portion of the
Common Area providing access to or parking for the Leased Premises are damaged by casualty to the extent that Tenant does not have reasonable access to or parking for the Leased Premises and Landlord has not within a reasonable time (not to exceed
ninety (90) days from the date of casualty) provided a reasonable parking alternative for Tenant at the Project or within reasonable proximity to the Building, then Landlord shall allow Tenant a proportionate abatement of Base Monthly Rent and
Property Operating Expenses during the time and to the extent the Leased Premises are unfit for occupancy for the purposes permitted under this Lease, or any portions of the Common Area providing access to or parking for the Leased Premises are
damaged by Casualty to the extent that Tenant does not have reasonable access to or parking for the Leased Premises, and in any of those events the Leased Premises are not occupied by Tenant as a result thereof. If a casualty: (i) shall have
damaged the parking facilities so that Tenant does not have reasonable access to or parking for the Leased Premises, then, subject to Laws, Restrictions and the rights of other tenants, Landlord shall use good faith efforts to explore reasonable
parking alternatives for Tenant at the Project or in offsite areas within reasonable proximity to the Building, and, in such event, Landlord shall be responsible for the costs of providing a shuttle to and from such offsite Parking and the Building,
provided that nothing herein shall be deemed to create any obligation of Landlord to incur significant expense or liability in doing so, (ii) shall have damaged the Cafe & Fitness Center, then, subject to Laws, Restrictions and the
rights of other tenants, Tenant shall have no obligation to pay any Property Operating Expenses associated with such facilities, and Landlord shall reasonably cooperate with Tenant to explore options for Tenant’s employees exercise elsewhere in
the Project, until such facilities are rebuilt, and/or (iii) shall have damaged a portion of the Common Areas necessary for Tenant’s access to the Building, then, subject to Laws, Restrictions and the rights of other tenants, Landlord
shall use good faith efforts to explore reasonable alternative means of access to the Building at the Project with Tenant, provided that nothing herein shall be deemed to create any obligation of Landlord to incur significant expense or liability in
doing so. 
 ARTICLE 11 

CONDEMNATION 
 11.1
Tenant’s Right To Terminate. Except as otherwise provided in Paragraph 11.4 below regarding temporary takings, Tenant shall have the option to terminate this Lease if, as a result of any taking, (i) all of the Leased Premises is taken,
or (ii) twenty-five percent (25%) or more of the Leased Premises is taken and the part of the Leased Premises that remains cannot, within a reasonable period of time, be made reasonably suitable for the continued operation of Tenant’s
business. Tenant must exercise such option within a reasonable period of time, to be effective on the later to occur of (i) the date that possession of that portion of the Leased Premises that is condemned is taken by the condemnor or
(ii) the date Tenant vacated the Leased Premises. 
 11.2 Landlord’s Right To Terminate. Except as otherwise provided in
Paragraph 11.4 below regarding temporary takings, Landlord shall have the option to terminate this Lease if, as a result of any taking, (i) all of the Leased Premises is taken, (ii) twenty-five percent (25%) or more of the Leased
Premises is taken and the part of the Leased Premises that remains cannot, within a reasonable period of time, be made reasonably suitable for the continued operation of Tenant’s business, or (iii) because of the Laws or Restrictions then
in force, the Leased Premises may not be used for the same use being made before such taking, whether or not restored as required by Paragraph 11.3 below. Any such option to terminate by Landlord must be exercised within a reasonable period of time,
to be effective as of the date possession is taken by the condemnor. 
 11.3 Restoration. If any part of the Leased Premises or the
Building is taken and this Lease is not terminated, then Landlord shall, to the extent not prohibited by Laws or Restrictions then in force, repair any damage occasioned thereby to the remainder thereof to a condition reasonably suitable for
Tenant’s continued operations and otherwise, to the extent practicable, in the manner and to the extent provided in Paragraph 10.1. 

11.4 Temporary Taking. If a material portion of the Leased Premises is temporarily taken for a period of one year or less and such
period does not extend beyond the Lease Expiration Date, this Lease shall remain in effect. If any material portion of the Leased Premises is temporarily taken for a period which exceeds one year or which extends beyond the Lease Expiration Date,
then the rights of Landlord and Tenant shall be determined in accordance with Paragraphs 11.1 and 11.2 above. 

  
 30 

 Building C 
  

11.5 Division Of Condemnation Award. Any award made for any taking of the Property, the Building, or the Leased Premises, or any portion
thereof, shall belong to and be paid to Landlord, and Tenant hereby assigns to Landlord all of its right, title and interest in any such award; provided, however, that Tenant shall be entitled to receive any portion of the award that is made
specifically (i) for the taking of personal property, inventory or trade fixtures belonging to Tenant, (ii) for the interruption of Tenant’s business or its moving costs, or (iii) for the value of any leasehold improvements
installed and paid for by Tenant. The rights of Landlord and Tenant regarding any condemnation shall be determined as provided in this Article, and each party hereby waives the provisions of Section 1265.130 of the California Code of Civil
Procedure, and the provisions of any similar law hereinafter enacted, allowing either party to petition the Supreme Court to terminate this Lease and/or otherwise allocate condemnation awards between Landlord and Tenant in the event of a taking of
the Leased Premises. 
 11.6 Abatement Of Rent. In the event of a taking of the Leased Premises which does not result in a
termination of this Lease (other than a temporary taking), then, as of the date possession is taken by the condemning authority, the Base Monthly Rent shall be reduced in the same proportion that the area of that part of the Leased Premises so taken
(less any addition to the area of the Leased Premises by reason of any reconstruction) bears to the area of the Leased Premises immediately prior to such taking. 

11.7 Taking Defined. The term “taking” or “taken” as used in this Article 11 shall mean any transfer
or conveyance of all or any portion of the Property or the Project to a public or quasi-public agency or other entity having the power of eminent domain pursuant to or as a result of the exercise of such power by such an agency, including any
inverse condemnation and/or any sale or transfer by Landlord of all or any portion of the Property or the Project to such an agency under threat of condemnation or the exercise of such power. 

ARTICLE 12 
 DEFAULT AND
REMEDIES 
 12.1 Events Of Tenant’s Default. Tenant shall be in default of its obligations under this Lease if any of the
following events occur: 
 (a) Tenant shall have failed to pay Base Monthly Rent or any Additional Rent when due; provided that Tenant shall
be entitled to receive written notice of late payment one time during each year of the Lease Term, and with respect to that one late payment, Tenant shall not be in default under this Paragraph 12.1(a) unless Tenant has failed to make the required
payment within three (3) days after such notice from Landlord. After the notice has been given, Landlord shall not be required to provide any further notices to Tenant; or 

(b) Tenant shall have done or permitted to be done any act, use or thing in its use, occupancy or possession of the Leased Premises or the
Building or Common Areas which is prohibited by the terms of this Lease or Tenant shall have failed to perform any term, covenant, or condition of this Lease (except those requiring the payment of Base Monthly Rent or Additional Rent, which failures
shall be governed by subparagraph (a) above) and such default is not cured within the shorter of (i) any specific time period expressly provided under this Lease for the performance of such term, covenant or condition, or (ii) thirty
(30) days after written notice from Landlord to Tenant specifying the nature of such default and requesting Tenant to cure the same, or within such longer period as is reasonably required in the event such default is curable but not within such
thirty (30) day period, provided such cure is promptly commenced within such thirty (30) day period and is thereafter diligently prosecuted to completion; or 

(c) (i) Tenant shall have sublet the Leased Premises or assigned or encumbered its interest in this Lease in violation of the provisions
contained in Article 7, or (ii) any guarantor shall have assigned or delegated its rights or obligations under the applicable guaranty without first obtaining Landlord’s written consent if and as required by the terms of the applicable
guaranty, in either case (i) or (ii), whether voluntarily or by operation of law; or 
 (d) Tenant shall have abandoned the Leased
Premises (as opposed to having vacated the same in accordance with Paragraph 4.1 above); or 
 (e) Tenant or any guarantor of this Lease
shall have permitted or suffered the sequestration or attachment of, or execution on, or the appointment of a custodian or receiver with respect to, all or any substantial part of the property or assets of Tenant (or such guarantor) or any property
or asset essential to the conduct of Tenant’s (or such guarantor’s) business, and Tenant (or such guarantor) shall have failed to obtain a return or release of the same within thirty (30) days thereafter, or prior to sale pursuant to
such sequestration, attachment or levy, whichever is earlier; or 
 (f) Tenant or any guarantor of this Lease shall have made a general
assignment of all or a substantial part of its assets for the benefit of its creditors; or 

  
 31 

 Building C 
  

(g) Tenant or any guarantor of this Lease shall have allowed (or sought) to have entered against it a decree or order which: (i) grants or
constitutes an order for relief, appointment of a trustee, or condemnation or a reorganization plan under the bankruptcy laws of the United States; (ii) approves as properly filed a petition seeking liquidation or reorganization under said
bankruptcy laws or any other debtor’s relief law or similar statute of the United States or any state thereof; or (iii) otherwise directs the winding up or liquidation of Tenant; provided, however, if any decree or order was entered
without Tenant’s consent or over Tenant’s objection, Landlord may not terminate this Lease pursuant to this Subparagraph if such decree or order is rescinded or reversed within ninety (90) days after its original entry; or 

(h) Tenant or any guarantor of this Lease shall have availed itself of the protection of any debtor’s relief law, moratorium law or other
similar law which does not require the prior entry of a decree or order. 
 (i) If during any period that Landlord (or its affiliate) and
Tenant (or its affiliate) are the landlord and tenant, respectively, under the Building D Lease, Tenant (or its affiliate) shall be in default of its obligations under the Building D Lease. Landlord shall have the right, acting alone, to elect from
time to time to delete and/or reinstate, as applicable, this subparagraph (i) and Paragraph 12.3(b) below by notice to Tenant delivered in accordance with Paragraph 13.10 below. If at any time Landlord makes such election, then Tenant agrees,
at Landlord’s request, to execute an amendment to this Lease the effect of which is to delete or reinstate, as applicable, this subparagraph (i) and Paragraph 12.3(b) below, and in the event of a deletion, to retain the reinstatement
right. 
 12.2 Landlord’s Remedies. In the event of any default by Tenant, and without limiting Landlord’s right to
indemnification as provided in Article 8.2, Landlord shall have the following remedies, in addition to all other rights and remedies provided by law or otherwise provided in this Lease, to which Landlord may resort cumulatively, or in the
alternative: 
 (a) Landlord may, at Landlord’s election, keep this Lease in effect and enforce, by an action at law or in equity, all
of its rights and remedies under this Lease including, without limitation, (i) the right to recover the rent and other sums as they become due by appropriate legal action, (ii) the right to make payments required by Tenant, or perform
Tenant’s obligations and be reimbursed by Tenant for the cost thereof with interest at a rate equal to the Default Interest Rate from the date the sum is paid by Landlord until Landlord is reimbursed by Tenant, and (iii) the remedies of
injunctive relief and specific performance to prevent Tenant from violating the terms of this Lease and/or to compel Tenant to perform its obligations under this Lease, as the case may be. 

(b) Landlord may, at Landlord’s election, terminate this Lease by giving Tenant written notice of termination, in which event this Lease
shall terminate on the date set forth for termination in such notice, in which event Tenant shall immediately surrender the Leased Premises to Landlord, and if Tenant fails to do so, Landlord may, without prejudice to any other remedy which it may
have for possession or arrearages in rent, enter upon and take possession of the Leased Premises and expel or remove Tenant and any other person who may be occupying the Leased Premises or any part thereof, without being liable for prosecution or
any claim for damages therefor. Any termination under this subparagraph shall not relieve Tenant from its obligation to pay to Landlord all Base Monthly Rent and Additional Rent then or thereafter due, or any other sums due or thereafter accruing to
Landlord, or from any claim against Tenant for damages previously accrued or then or thereafter accruing. In no event shall any one or more of the following actions by Landlord, in the absence of a written election by Landlord to terminate this
Lease constitute a termination of this Lease: 
 (i) Appointment of a receiver or keeper in order to protect Landlord’s interest
hereunder; 
 (ii) Consent to any subletting of the Leased Premises or assignment of this Lease by Tenant, whether pursuant to the
provisions hereof or otherwise; or 
 (iii) Any action taken by Landlord or its partners, principals, members, officers, agents, employees,
or servants, which is intended to mitigate the adverse effects of any breach of this Lease by Tenant, including, without limitation, any action taken to maintain and preserve the Leased Premises on any action taken to relet the Leased Premises or
any portion thereof for the account at Tenant and in the name of Tenant. 
 (c) In the event Tenant breaches this Lease and abandons the
Leased Premises, Landlord may terminate this Lease, but this Lease shall not terminate unless Landlord gives Tenant written notice of termination. If Landlord does not terminate this Lease by giving written notice of termination, Landlord may
enforce all its rights and remedies under this Lease, including the right and remedies provided by California Civil Code Section 1951.4 (“lessor may continue lease in effect after lessee’s breach and abandonment and recover rent as it
becomes due, if lessee has right to sublet or assign, subject only to reasonable limitations”), as in effect on the Effective Date of this Lease. 

  
 32 

 Building C 
  

(d) In the event Landlord terminates this Lease, Landlord shall be entitled, at Landlord’s election, to the rights and remedies provided
in California Civil Code Section 1951.2, as in effect on the Effective Date of this Lease. For purposes of computing damages pursuant to Section 1951.2, an interest rate equal to the Default Interest Rate shall be used. Such damages shall
include, without limitation: 
 (i) The worth at the time of the award of the unpaid rent which had been earned at the time of termination;
plus 
 (ii) The worth at the time of award of the amount by which the unpaid rent which would have been earned after termination until the
time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus 
 (iii) The worth at the
time of award of the amount by which the unpaid rent for the balance of the term after the time of award exceeds the amount of such rental loss that Tenant proves could be reasonably avoided, computed by discounting such amount at the discount rate
of the Federal Reserve Bank of San Francisco, at the time of award plus one percent; plus 
 (iv) Any other amount necessary to compensate
Landlord for all detriment proximately caused by Tenant’s failure to perform Tenant’s obligations under this Lease, or which in the ordinary course of things would be likely to result therefrom, including without limitation, the following:
(i) expenses for cleaning, repairing or restoring the Leased Premises, (ii) expenses for altering, remodeling or otherwise improving the Leased Premises for the purpose of reletting, including removal of existing leasehold improvements and/or
installation of additional leasehold improvements (regardless of how the same is funded, including reduction of rent, a direct payment or allowance to a new tenant, or otherwise), (iii) broker’s fees allocable to the remainder of the term
of this Lease, advertising costs and other expenses of reletting the Leased Premises; (iv) costs of carrying and maintaining the Leased Premises, such as taxes, insurance premiums, utility charges and security precautions (although the
foregoing shall not in any way modify Paragraph 5.3 above), (v) expenses incurred in removing, disposing of and/or storing any of Tenant’s personal property, inventory or trade fixtures remaining therein; (vi) reasonable
attorney’s fees, expert witness fees, court costs and other reasonable expenses incurred by Landlord (but not limited to taxable costs) in retaking possession of the Leased Premises, establishing damages hereunder, and releasing the Leased
Premises; and (vii) any other expenses, costs or damages otherwise incurred or suffered as a result of Tenant’s default. 
 (e)
Pursuant to California Code of Civil Procedure Section 1161.1, Landlord may accept a partial payment of Rent after serving a notice pursuant to California Code of Civil Procedure Section 1161, and may without further notice to the Tenant,
commence and pursue an action to recover the difference between the amount demanded in that notice and the payment actually received. This acceptance of such a partial payment of Rent does not constitute a waiver of any rights, including any right
the Landlord may have to recover possession of the Leased Premises. Further, Tenant agrees that any notice given by Landlord pursuant to Paragraph 12.1 of the Lease shall satisfy the requirements for notice under California Code of Civil Procedure
Section 1161, and Landlord shall not be required to give any additional notice in order to be entitled to commence an unlawful detainer proceeding. 

12.3 Landlord’s Default And Tenant’s Remedies.  

(a) In the event Landlord fails to perform its obligations under this Lease, Landlord shall nevertheless not be in default under the terms of
this Lease until such time as Tenant shall have first given Landlord written notice specifying the nature of such failure to perform its obligations, and then only after Landlord shall have had thirty (30) days following its receipt of such
notice within which to perform such obligations; provided that, if longer than thirty (30) days is reasonably required in order to perform such obligations, Landlord shall have such longer period. In the event of Landlord’s default as
above set forth, then, and only then, Tenant may then proceed in equity or at law to compel Landlord to perform its obligations and/or to recover damages proximately caused by such failure to perform (except as and to the extent Tenant has waived
its right to damages as provided in this Lease). 
 (b) Subparagraph (a) above shall also be applicable if Landlord (or its affiliate)
and Tenant (or its affiliate) are the landlord and tenant, respectively, under the Building D Lease and Landlord (or its affiliate) is in default of its obligations under the Building D Lease. This subparagraph (b) shall automatically terminate
and be void and of no force or effect at any time that either (i) Landlord (or its affiliate) is not the landlord under the Building D Lease, or (ii) Paragraph 12.1(i) above has been deleted pursuant to and in accordance with such
Paragraph 12.1(i); provided, however, that if at any time Paragraph 12.1(i) is reinstated pursuant to and in accordance with such Paragraph 12.1(i), then this subparagraph (b) shall be reinstated as well. 

  
 33 

 Building C 
  

12.4 Limitation Of Tenant’s Recourse. Tenant’s sole recourse against Landlord shall be to Landlord’s interest in the
Project and the revenues, insurance proceeds and condemnation awards therefrom; provided, however, that in no event shall Tenant have recourse to any sums distributed to Landlord’s members or manager(s) in the ordinary course of business
(including but not limited to sale or refinancing proceeds distributed upon a sale or refinancing, as applicable). If Landlord is a corporation, trust, partnership, joint venture, limited liability company, unincorporated association, or other form
of business entity, Tenant agrees that (i) the obligations of Landlord under this Lease shall not constitute personal obligations of the officers, directors, trustees, partners, joint venturers, members, managers, owners, stockholders, or other
principals of such business entity, and (ii) Tenant shall have recourse only to the interest of such corporation, trust, partnership, joint venture, limited liability company, unincorporated association, or other form of business entity in the
Building and the Common Areas for the satisfaction of such obligations and not against the assets of such officers, directors, trustees, partners, joint venturers, members, managers, owners, stockholders or principals. Additionally, if Landlord is a
partnership or limited liability company, then Tenant covenants and agrees: 
 (a) No partner, manager, or member of Landlord shall be sued
or named as a party in any suit or action brought by Tenant with respect to any alleged breach of this Lease (except to the extent necessary to secure jurisdiction over the partnership or limited liability company and then only for that sole
purpose); 
 (b) No service of process shall be made against any partner, manager, or member of Landlord except for the sole purpose of
securing jurisdiction over the partnership; and 
 (c) No writ of execution will ever be levied against the assets of any partner, manager,
or member of Landlord other than to the extent of his or her interest in the assets of the partnership or limited liability company constituting Landlord. 

Tenant further agrees that each of the foregoing covenants and agreements shall be enforceable by Landlord and by any partner or manager or member of Landlord
and shall be applicable to any actual or alleged misrepresentation or nondisclosure made regarding this Lease or the Leased Premises or any actual or alleged failure, default or breach of any covenant or agreement either expressly or implicitly
contained in this Lease or imposed by statute or at common law. 
 12.5 Limitation Of Tenant’s Recourse. Notwithstanding any
provision of this Lease to the contrary, Tenant shall not be liable to Landlord for consequential or special damages, except that this sentence (i) shall not limit the indemnification obligations of Tenant hereunder with respect to third party
claims, (ii) shall not apply to claims for the breach by Tenant of Tenant’s obligations under Paragraph 4.11, (iii) shall not limit Landlord’s right to recover from Tenant, (a) damages for Tenant’s breach of this Lease
as described in Paragraph 12.2 above, to the extent recoverable from Tenant under applicable Laws, or (b) consequential damages if Tenant holds over after the Lease Expiration Date or prior termination of this Lease, provided that Landlord
delivers to Tenant a Vacation Notice as and when required by Paragraph 13.2. 
 12.6 Tenant’s Waiver. Landlord and Tenant agree
that the provisions of Paragraph 12.3 above are intended to supersede and replace the provisions of California Civil Code Sections 1932(1), 1941 and 1942, and accordingly, Tenant hereby waives the provisions of California Civil Code Sections
1932(1), 1941 and 1942 and/or any similar or successor law regarding Tenant’s right to terminate this Lease or to make repairs and deduct the expenses of such repairs from the rent due under this Lease.  

ARTICLE 13 
 GENERAL
PROVISIONS 
 13.1 Taxes On Tenant’s Property. Tenant shall pay before delinquency any and all taxes, assessments, license
fees, use fees, permit fees and public charges of whatever nature or description levied, assessed or imposed against Tenant or Landlord by a governmental agency arising out of, caused by reason of or based upon Tenant’s estate in this Lease,
Tenant’s ownership of property, improvements made by Tenant to the Leased Premises or the Common Areas, improvements made by Landlord for Tenant’s use within the Leased Premises or the Common Areas, Tenant’s use (or estimated use) of
public facilities or services or Tenant’s consumption (or estimated consumption) of public utilities, energy, water or other resources (collectively, “Tenant’s Interest”). Upon demand by Landlord, Tenant shall furnish
Landlord with satisfactory evidence of these payments. If any such taxes, assessments, fees or public charges are levied against Landlord, Landlord’s property, the Building, the Property, or the Project, or if the assessed value of the
Building, the Property, or the Project is increased by the inclusion therein of a value placed upon Tenant’s Interest, regardless of the validity thereof, Landlord shall have the right to require Tenant to pay such taxes, and if not paid and
satisfactory evidence of payment delivered to Landlord at least ten (10) days prior to delinquency, then Landlord shall have the right to pay such taxes on Tenant’s behalf and to invoice Tenant for the same, in either case whether before
or after the expiration or earlier termination of the Lease Term. Tenant shall, within the earlier to occur of (a) thirty 

  
 34 

 Building C 
  

(30) days of the date it receives an invoice from Landlord setting forth the amount of such taxes, assessments, fees, or public charge so levied, or (b) the due date of such invoice, pay to
Landlord, as Additional Rent, the amount set forth in such invoice. Failure by Tenant to pay the amount so invoiced within such time period shall be conclusively deemed a default by Tenant under this Lease. Tenant shall have the right to bring suit
in any court of competent jurisdiction to recover from the taxing authority the amount of any such taxes, assessments, fees or public charges so paid. 

13.2 Holding Over. This Lease shall terminate without further notice on the Lease Expiration Date (as set forth in Article 1). Any
holding over by Tenant after expiration of the Lease Term shall neither constitute a renewal nor extension of this Lease nor give Tenant any rights in or to the Leased Premises except as expressly provided in this Paragraph. Any such holding over to
which Landlord has consented shall be construed to be a tenancy from month to month, on the same terms and conditions herein specified insofar as applicable, except that the Base Monthly Rent shall be increased to an amount equal to one hundred
twenty-five percent (125%) of the Monthly Base Rent for the last month immediately preceding such holding over for the first two (2) months or any such holding over, and thereafter one hundred fifty percent (150%) of the Base Monthly
Rent payable during the last full month immediately preceding such holding over. Without limiting the foregoing, in the event of a holding over to which Landlord has consented, any rights of Landlord or obligations of Tenant set forth in this Lease
and purporting to apply during the term of this Lease, shall nonetheless also be deemed to apply during any such hold over period. Tenant acknowledges that if Tenant holds over without Landlord’s consent, such holding over may compromise or
otherwise affect Landlord’s ability to enter into new leases with prospective tenants regarding the Leased Premises. 
 Therefore, in
the event Tenant does not vacate the Leased Premises in accordance with the terms of this Paragraph 13.2 on or before the expiration of the Lease Term (or the expiration of a holdover term, if applicable) after receiving at least thirty
(30) days’ advance written notice from Landlord demanding that Tenant vacate the Leased Premises and otherwise satisfying the requirements set forth below (a “Vacation Notice”), which notice may be given to Tenant at any
time during the last sixty (60) days of the Lease Term or during any holdover period, Tenant shall be liable for all damages (including attorneys’ fees and expenses) of whatever type (including consequential damages) incurred by Landlord
as a result of such holding over, and Tenant shall protect, defend, indemnify and hold Landlord harmless from and against all claims resulting from such failure to vacate, including, without limiting the foregoing, any claims made by any succeeding
tenant founded upon such failure to surrender, and any losses suffered by Landlord, including lost profits, resulting from such failure to surrender. The Vacation Notice shall specifically refer to this Lease and the address of the Building, and
shall include (on the first page of the Vacation Notice) the following language in bold, capitalized font: “NOTICE: UNDER PARAGRAPH 13.2 OF THE LEASE, TENANT’S FAILURE TO VACATE THE LEASED PREMISES BY THE EXPIRATION OR EARLIER
TERMINATION OF THE LEASE TERM (OR HOLDOVER TERM IF APPLICABLE) MAY RESULT IN SIGNIFICANT DAMAGES TO LANDLORD, INCLUDING CONSEQUENTIAL DAMAGES.” 

13.3 Subordination To Mortgages. This Lease is subject to and subordinate to all ground leases, mortgages and deeds of trust which
affect the Building, the Property, or the Project and which are of public record as of the Effective Date of this Lease, and to all renewals, modifications, consolidations, replacements and extensions thereof. Notwithstanding the foregoing, if
requested by Landlord, Tenant agrees, within ten (10) days after Landlord’s written request therefor, to execute, acknowledge and deliver to Landlord any and all documents or instruments reasonably requested by Landlord or by the existing
lessor or lender to assure the subordination of this Lease to such ground lease, mortgage or deed of trust, including but not limited to a subordination agreement in the form attached to this Lease as Exhibit I or such other customary form as
any such lessor or lender may require (an “SNDA”). If the form of SNDA is different than the form attached to this Lease as Exhibit I, then Tenant shall have the right to make reasonable comments to such form provided that Tenant
shall not be entitled to object to any provision of such SNDA which is substantially the same as a provision set forth in Exhibit I. If the lessor under any such ground lease or any lender holding any such mortgage or deed of trust shall advise
Landlord that it desires or requires this Lease to be made prior and superior thereto, then, upon written request of Landlord to Tenant, Tenant shall promptly execute, acknowledge and deliver any and all customary or reasonable documents or
instruments which Landlord and such lessor or lender deems necessary or desirable to make this Lease prior thereto, subject to Tenant’s right to make reasonable comments to such documents or instruments (provided that Tenant shall not be
entitled to object to any provision of such documents or instruments which is substantially the same as a provision set forth in Exhibit I). Tenant hereby consents to Landlord’s ground leasing the land underlying the Building, the Property, or
the Project and/or encumbering the Building, the Property, or the Project as security for future loans on such terms as Landlord shall desire, all of which future ground leases, mortgages or deeds of trust shall be subject to and subordinate to this
Lease. However, if any lessor under any such future ground lease or any lender holding such future mortgage or deed of trust shall desire or require that this Lease be made subject to and subordinate to such future ground lease, mortgage or deed of
trust, then Tenant agrees, within ten (10) days after Landlord’s written request therefor, to execute, acknowledge and deliver to Landlord any and all documents or instruments requested by Landlord or by such lessor or lender to 

  
 35 

 Building C 
  

assure the subordination of this Lease to such future ground lease, mortgage or deed of trust, but only if such lessor or lender agrees not to disturb Tenant’s quiet possession of the Leased
Premises so long as Tenant is not in default under this Lease beyond any applicable notice and cure periods expressly set forth in this Lease, and subject to Tenant’s right to make reasonable comments to such documents or instruments (provided
that Tenant shall not be entitled to object to any provision of such documents or instruments which is substantially the same as a provision set forth in Exhibit I). Tenant’s failure to execute and deliver such documents or instruments within
ten (10) days after Landlord’s request therefor shall be a material default by Tenant under this Lease, provided that Landlord provides Tenant with a written notice of such default and Tenant continues to fail to deliver such documentation
within four (4) days of receipt of such default notice, in which case no further notice shall be required under Paragraph 12.1(c) or any other provision of this Lease, and Landlord shall have all of the rights and remedies available to Landlord
as Landlord would otherwise have in the case of any other material default by Tenant, it being agreed and understood by Tenant that Tenant’s failure to so deliver such documents or instruments in a timely manner could result in Landlord being
unable to perform committed obligations to other third parties which were made by Landlord in reliance upon this covenant of Tenant. If Landlord assigns the Lease as security for a loan, Tenant agrees to execute such documents as are reasonably
requested by the lender and to provide reasonable provisions in the Lease protecting such lender’s security interest which are customarily required by institutional lenders making loans secured by a deed of trust. 

Tenant hereby agrees, promptly upon request by Landlord, to execute, have acknowledged, and deliver to Landlord an SNDA substantially in the
form of Exhibit I attached hereto, and Landlord agrees to cause Landlord’s existing mortgage lender to execute, have acknowledged, and, as a condition to the effectiveness of this Lease, either (a) have the same recorded in the
Official Records of Santa Clara County, or (b) deliver a complete original of the same to Tenant, in either case within 30 days after the Effective Date of this Lease, failing which Tenant shall have the right to terminate this Lease by written
notice to Landlord delivered within ten (10) days after the end of such 30 day period, if at all. 
 13.4 Tenant’s Attornment
Upon Foreclosure. Tenant shall, upon request, attorn (i) to any purchaser of the Building, the Property, or the Project at any foreclosure sale or private sale conducted pursuant to any security instruments encumbering the Building, the
Property, or the Project, (ii) to any grantee or transferee designated in any deed given in lieu of foreclosure of any security interest encumbering the Building, the Property, or the Project, or (iii) to the lessor under an underlying
ground lease of the land underlying the Building, the Property, or the Project, should such ground lease be terminated; provided that such purchaser, grantee or lessor recognizes Tenant’s rights under this Lease. 

13.5 Mortgagee Protection. In the event of any default on the part of Landlord, Tenant will give notice by registered mail to any
Lender or lessor under any underlying ground lease who shall have requested, in writing, to Tenant that it be provided with such notice, and Tenant shall offer such Lender or lessor a reasonable opportunity to cure the default. 

13.6 Estoppel Certificate. Tenant will, following any request by Landlord, promptly execute and deliver to Landlord an estoppel
certificate substantially in form attached as Exhibit J, (i) certifying that this Lease is unmodified and in full force and effect, or, if modified, stating the nature of such modification and certifying that this Lease, as so modified,
is in full force and effect, (ii) stating the date to which the rent and other charges are paid in advance, if any, (iii) acknowledging that there are not, to Tenant’s knowledge, any uncured defaults on the part of Landlord hereunder,
or specifying such defaults if any are claimed, and (iv) certifying such other information about this Lease as may be reasonably requested by Landlord, its Lender or prospective lenders, investors or purchasers of the Building, the Property, or
the Project. Tenant’s failure to execute and deliver such estoppel certificate within ten (10) days after Landlord’s request therefor shall be a material default by Tenant under this Lease, provided that Landlord provides Tenant with
a written notice of such default and Tenant continues to fail to deliver such documentation within four (4) days of receipt of such default notice, in which case no further notice shall be required under Paragraph 12.1(c) or any other provision
of this Lease, and Landlord shall have all of the rights and remedies available to Landlord as Landlord would otherwise have in the case of any other material default by Tenant, it being agreed and understood by Tenant that Tenant’s failure to
so deliver such estoppel certificate in a timely manner could result in Landlord being unable to perform committed obligations to other third parties which were made by Landlord in reliance upon this covenant of Tenant. Landlord and Tenant intend
that any statement delivered pursuant to this paragraph may be relied upon by any Lender or purchaser or prospective Lender or purchaser of the Building, the Property, or any interest in them. Tenant’s certifications are, however, made solely
to estop Tenant from asserting against the party(ies) named therein (other than Landlord), facts or claims contrary to those stated therein, and such estoppel certificate shall be binding on Tenant vis-à-vis the party(ies) named therein
(other than Landlord) but shall not modify in any way, Tenant’s relationship, obligations or rights vis-à-vis Landlord. 

13.7 Tenant’s Financial Information. Tenant shall, within ten (10) days after Landlord’s request therefor, deliver to
Landlord a copy of Tenant’s (and any guarantor’s) current audited financial 

  
 36 

 Building C 
  

statements (including a balance sheet, income statement and statement of cash flow, all prepared in accordance with generally accepted accounting principles), a list of all of Tenant’s
creditors with current contact information, and any such other information reasonably requested by Landlord regarding Tenant’s financial condition; provided, however, that as long as the common stock of Tenant (or its assigns permitted pursuant
to this Lease or otherwise approved by Landlord in writing) is publicly-traded on a United States national stock exchange, and such information is available as part of Tenant’s or such Permitted Transferee’s 10-K or 10-Q report filings on
the SEC’s Edgar website, and such materials are current per SEC filing requirements, then such requirement shall be fulfilled by such filings. Landlord shall be entitled to disclose such financial statements or other information to its Lender,
to any present or prospective principal of or investor in Landlord, or to any prospective Lender or purchaser of the Building, the Property, or any portion thereof or interest therein. Any such financial statement or other information which is
marked “confidential” or “company secrets” (or is otherwise similarly marked by Tenant) shall be confidential and shall not be disclosed by Landlord to any third party except as specifically provided in this paragraph, unless the
same becomes a part of the public domain without the fault of Landlord. 
 13.8 Transfer By Landlord. Landlord and its successors in
interest shall have the right to transfer their interest in the Building, the Property, or any portion thereof at any time and to any person or entity; provided, however, that if Landlord sells the Building at any time before the
Landlord’s Additional Work is Substantially Complete, Menlo Equities Development Company IX LLC (“MEDCO IX”) will enter into a development agreement with the buyer pursuant to which MEDCO IX shall be the developer until the
Landlord’s Additional Work is Substantially Complete. In the event of any such transfer, the Landlord originally named herein (and in the case of any subsequent transfer, the transferor), from the date of such transfer, shall be automatically
relieved, without any further act by any person or entity, of all liability for (i) the performance of the obligations of the Landlord hereunder which may accrue after the date of such transfer if its transferee agrees to assume and perform
such obligations of the Landlord hereunder, and (ii) repayment of any unapplied portion of any security deposit (upon transferring or crediting the same to the transferee). Tenant shall attorn to any such transferee. After the date of any such
transfer, the term “Landlord” as used herein shall mean the transferee of such interest in the Building, the Property, or the Project. 

13.9 Force Majeure. Any prevention, delay or stoppage due to strikes, lockouts, labor disputes, acts of God, acts of war, terrorist
acts, inability to obtain services, labor, or materials or reasonable substitutes therefor, governmental actions, civil commotions, fire or other casualty, delay in obtaining approvals, building permits and certificates of occupancy within normal
time frames, and other causes beyond the reasonable control of the party obligated to perform, except with respect to the obligations imposed with regard to Rent and other charges to be paid by Tenant pursuant to this Lease (collectively, a
“Force Majeure”), notwithstanding anything to the contrary contained in this Lease, shall excuse the performance of such party for a period equal to any such prevention, delay or stoppage and, therefore, if this Lease specifies a
time period for performance of an obligation of either party, that time period shall be extended by the period of any delay in such party’s performance caused by a Force Majeure. 

13.10 Notices. Any notice required or permitted to be given under this Lease other than statutory notices, shall be in writing and
(i) personally delivered, (ii) sent by United States mail, registered or certified mail, postage prepaid, return receipt requested, or (iii) sent by Federal Express or similar nationally recognized overnight courier service, and in
all cases addressed as follows, and such notice shall be deemed to have been given upon the date of actual receipt or delivery (or refusal to accept delivery) at the address specified below (or such other addresses as may be specified by notice in
the foregoing manner) as indicated on the return receipt or air bill: 
  

			
	If to Landlord:		 Santa Clara Campus Property Owner I LLC
 490
California Avenue
 4th Floor
 Palo Alto, California 94306

Attention: Henry Bullock/Richard Holmstrom

		
	with a copy to:		 Mintz Levin Cohn Ferris Glovsky and Popeo PC

44 Montgomery Street
 36th Floor
 San Francisco, California 94104

Attention: Paul Churchill

		
	If to Tenant:		 Prior to the Lease Commencement Date:
 Aruba
Networks, Inc.
 1344 Crossman Avenue
 Sunnyvale, California
94089
 Attn: Mr. Michael Phelps,
 Sr. Director of Global
Real Estate

  
 37 

 Building C 
  

			
	With a copy to:		 Sheppard Mullin Richter & Hampton

Four Embarcadero Center
 17th Floor
 San Francisco, California 94111

Attention: Doug Van Gessel

		
	If to Tenant:		 After the Lease Commencement Date:
 Aruba
Networks, Inc.
 3335 Scott Boulevard
 Santa Clara California
95054
 Attention: Mr. Michael Phelps,
 Sr. Director of
Global Real Estate

		
	with a copy to:		 Sheppard Mullin Richter & Hampton

Four Embarcadero Center
 17th Floor
 San Francisco, California 94111

Attention: Doug Van Gessel

 Any notice given in accordance with the foregoing shall be deemed received upon actual receipt or refusal to accept delivery.
Any notice required by statute and not waived in this Lease shall be given and deemed received in accordance with the applicable statute or as otherwise provided by law. 

13.11 Attorneys’ Fees and Costs. In the event any party shall bring any action, arbitration, or other proceeding alleging a breach
of any provision of this Lease, or a right to recover rent, to terminate this Lease, or to enforce, protect, interpret, determine, or establish any provision of this Lease or the rights or duties hereunder of either party, the prevailing party shall
be entitled to recover from the non-prevailing party as a part of such action or proceeding, or in a separate action for that purpose brought within one year from the determination of such proceeding, reasonable attorneys’ fees, expert witness
fees, court costs and reasonable disbursements, made or incurred by the prevailing party. 
 13.12 Definitions. Any term that is
given a special meaning by any provision in this Lease shall, unless otherwise specifically stated, have such meaning wherever used in this Lease or in any Addenda or amendment hereto. In addition to the terms defined in Article 1, the following
terms shall have the following meanings: 
 (a) Real Property Taxes. The term “Real Property Tax” or “Real
Property Taxes” shall each mean Tenant’s Building Share of the following (to the extent applicable to any portion of the Lease Term, regardless of when the same are imposed, assessed, levied, or otherwise charged): (i) all
taxes, assessments, levies and other charges of any kind or nature whatsoever, general and special, foreseen and unforeseen (including all installments of principal and interest required to pay any general or special assessments for public
improvements and any increases resulting from reassessments caused by any change in ownership or new construction), now or hereafter imposed by any governmental or quasi-governmental authority or special district having the direct or indirect power
to tax or levy assessments, which are levied or assessed for whatever reason against the Property or any portion thereof, or Landlord’s interest herein, or the fixtures, equipment and other property of Landlord that is an integral part of the
Property and located thereon, or Landlord’s business of owning, leasing or managing the Property or the gross receipts, income or rentals from the Property, (ii) all charges, levies or fees imposed by any governmental authority against
Landlord by reason of or based upon the use of or number of parking spaces within the Property, the amount of public services or public utilities used or consumed (e.g. water, gas, electricity, sewage or waste water disposal) at the Property, the
number of persons employed by tenants of the Property, the size (whether measured in area, volume, number of tenants or whatever) or the value of the Property, or the type of use or uses conducted within the Property, and all costs and fees
(including attorneys’ fees) reasonably incurred by Landlord in contesting in good faith any Real Property Tax and in negotiating with public authorities as to any Real Property Tax. In the event the Project is developed in a manner which
results in separate legal parcels comprising some or all of the Common Areas, then with respect to those Common Area parcels, Real Property Taxes shall be calculated using Tenant’s Project Share (as opposed to Tenant’s Building Share). If,
at any time during the Lease Term, the taxation or assessment of the Property prevailing as of the Effective Date of this Lease shall be altered so that in lieu of or in addition to any the Real Property Tax described above there shall be levied,
awarded or imposed (whether by reason of a change in the method of taxation or assessment, creation of a new tax or charge, or any other cause) an alternate, substitute, or additional use or charge (i) on the value, size, use or occupancy of
the Property or Landlord’s interest therein or (ii) on or measured by the gross receipts, income or rentals from the Property, or on Landlord’s business of owning, leasing or managing the Property or (iii) computed in any manner
with respect to the operation of 

  
 38 

 Building C 
  

the Property, then any such tax or charge, however designated, shall be included within the meaning of the terms “Real Property Tax” or “Real Property Taxes” for purposes of
this Lease. Notwithstanding the foregoing, the terms “Real Property Tax” or “Real Property Taxes” shall not include estate, inheritance, gift or franchise taxes of Landlord or the federal or state income tax imposed on
Landlord’s income from all sources, transfer taxes, any items which are in the nature of Taxes but are included in Property Maintenance Costs (in which case they shall be payable under that category) or expressly are excluded from Property
Maintenance Costs (in which case they shall not be payable by Tenant), including, without limitation, certain of the items excluded pursuant to Paragraph 13.12(xviii) below) and any real estate taxes directly payable by Tenant or any other tenant of
the Project (i.e., not paid by Landlord) under the applicable provisions of their respective leases. If Landlord receives a refund of Real Property Taxes or a credit against its future Real Property Taxes for any calendar year during the Lease Term
for which Tenant paid Tenant’s Share of Real Property Taxes, Landlord shall, at its election, either pay to Tenant, or credit against subsequent payments of Rent due hereunder, an amount equal to Tenant’s Building Share or Tenant’s
Project Share (as applicable) of the refund, net of any reasonable, actual out-of-pocket expenses incurred by Landlord in achieving such refund; provided, however, if this Lease shall have expired or is otherwise terminated, Landlord shall refund in
cash any such refund or credit due to Tenant within thirty (30) days after Landlord’s receipt of such refund or its receipt of such credit against future Real Property Taxes. Landlord’s obligation to so refund to Tenant any such
refund or credit of Real Property Taxes shall survive such expiration or termination. If the Cafe & Fitness Center is used only by certain tenants of the Project or Property, then Landlord shall have the right to allocate Real Property
Taxes attributable to such Cafe & Fitness Center solely to those tenants who have access to the Cafe & Fitness Center. 

(b) Landlord’s Insurance Costs. The term “Landlord’s Insurance Costs” shall mean (to the extent applicable
to any portion of the Lease Term, regardless of when the same are incurred): 
 (i) Tenant’s Building Share of the costs to Landlord to
carry and maintain the policies of fire and property damage insurance for the Building and general liability and any other insurance required or permitted to be carried by Landlord pursuant to Article 9, together with any deductible amounts paid by
Landlord upon the occurrence of any insured casualty or loss, but only to the extent such deductible is not in excess of Fifty Thousand Dollars ($50,000) per occurrence for non-earthquake insurance policies and not in excess of five percent
(5%) per occurrence of the full replacement cost of the Building in the case of policies of earthquake insurance; provided that if Tenant’s Project Share or Tenant’s Building Share, as relevant, of any earthquake deductible will
exceed an amount equal to Two and 00/100 Dollars ($2.00) per square foot of the rentable area in the Leased Premises in a particular calendar year (the “Annual Casualty Deductible Cap”) then only an amount up to such Annual Casualty
Deductible Cap shall be paid by Tenant in any calendar year, but Tenant’s Project Share or Tenant’s Building Share, as relevant, of excess amounts of such deductible may be carried forward, subject to the same Annual Casualty Deductible
Cap limitation, for payment in each subsequent year, up to the expiration or earlier termination of the Lease Term (as the same may be extended). If Tenant terminates this Lease under Article 10 as a result of a casualty, Tenant’s obligation to
pay any deductible with respect to that casualty shall not exceed Fifty Thousand Dollars ($50,000) (if the casualty is not the result of an earthquake) or the Annual Casualty Deductible Cap (if the casualty is the result of an earthquake). If
Landlord terminates this Lease under Article 10 as a result of a casualty, Tenant shall have no obligation to pay Landlord’s insurance deductible; plus 

(ii) without duplication of amounts payable pursuant to subparagraph (i) above, to the extent any of the insurance policies carried by
Landlord are specific to the Project as a whole (as opposed to the Building or the Property), then, Tenant’s Project Share of the costs to Landlord to carry and maintain the policies of fire and property damage insurance for the Project (as
opposed to just the Building or the Property) and general liability and any other insurance required or permitted to be carried by Landlord pursuant to Article 9 which is applicable to the Project (as opposed to just the Building or the Property),
together with any deductible amounts paid by Landlord upon the occurrence of any insured casualty or loss to the extent permitted pursuant to Paragraph 13.12(b)(i) above. 

(c) Property Maintenance Costs. The term “Property Maintenance Costs” shall mean (to the extent applicable to any
portion of the Lease Term, regardless of when the same are incurred): 
 (i) monthly professional management fees equal to 2.5% of Base
Monthly Rent (the “Management Fee”), plus Tenant’s Building Share of all other costs and expenses (except Landlord’s Insurance Costs and Real Property Taxes) paid or incurred by Landlord in protecting, operating,
maintaining, repairing and preserving the Building and the Property and all parts thereof, including without limitation, (A) the amortizing portion of any costs incurred by Landlord in the making of any modifications, alterations or
improvements required by any governmental authority as set forth in Article 6, which are so amortized during the Lease Term, and (B) such other costs as may be paid or incurred with respect to operating, maintaining, and preserving the Building
or the Property, such as repairing and resurfacing the exterior surfaces of the Building (including roofs), repairing and replacing 

  
 39 

 Building C 
  

structural parts of the Building, and repairing and replacing, when necessary, electrical, plumbing, and HVAC systems serving the Building; provided, however, that Tenant shall not be
responsible for any capital repairs or replacements costing over $10,000 individually, which are incurred by Landlord during the initial, unextended Lease Term except to the extent such capital repairs or replacements are necessitated by
Tenant’s breach of this Lease, and subject to the last two (2) sentences of Paragraph 5.1(b) above; plus 
 (ii) without
limitation or duplication of the foregoing, Tenant’s Project Share of all costs and expenses (except Landlord’s Insurance Costs and Real Property Taxes) paid or incurred by Landlord in protecting, operating, maintaining, repairing and
preserving the Project (as opposed to just the Building or the Property) and all parts thereof (excluding the Building and the Other Buildings); plus 

(iii) costs of maintaining, repairing, and operating the Cafe & Fitness Center (or the café or fitness center portions
thereof, if applicable) and, notwithstanding any contrary allocation pursuant to Tenant’s Project Share, shall be allocated among the Building, Buildings A, B, and D, and any additional buildings in the Project that have the use of the
Cafe & Fitness Center (or the applicable portions thereof), and any buildings that do not have the use of the Cafe & Fitness Center (or the applicable portions thereof) shall be excluded from such allocation, or such costs shall be
equitably prorated, as applicable; plus 
 (iv) without limitation or duplication of the foregoing, Tenant’s Project Share of all
costs and expenses paid or incurred by Landlord for employee shuttles and other transportation management efforts at the Project. 
 (d)
Property Operating Expenses. The term “Property Operating Expenses” shall mean and include all Real Property Taxes, plus all Landlord’s Insurance Costs, plus all Property Maintenance Costs. If the occupancy of the
Building or Project, during any calendar year is less than ninety-five percent (95%), Landlord shall make adjustments to the variable components of Property Operating Expenses for that calendar year, as reasonably determined by Landlord to determine
the amount of Property Operating Expenses that would have been incurred had the Building and Project been ninety-five percent (95%) occupied. Such adjusted variable components of Property Operating Expenses will be considered to have been the
amount of Property Operating Expenses for that calendar year for reimbursement purposes hereunder. For purposes hereunder, the term “variable components” includes only those components of Property Operating Expenses that are affected by
variations in occupancy levels as determined by Landlord. 
 Notwithstanding the provisions of Paragraph 13.12(c), the following are specifically excluded
from the definition of Property Operating Expenses and Tenant shall have no obligation to pay directly or reimburse Landlord for all or any portion of the following except to the extent any of the following are caused by the actions or inactions of
Tenant, or result from the failure of Tenant to comply with the terms of this Lease: 
 (i) Landlord’s non-cash charges, such as
depreciation (except for the amortization of capital or other items to the extent provided for in this Lease), 
 (ii) any payments of
points, interest or principal relating to any debt secured by the Leased Premises, 
 (iii) costs associated with the operation of the
business of the ownership or entity which constitutes “Landlord” (as distinguished from the costs of Leased Premises operations), including, but not limited to, partnership accounting and legal matters, accounting, payroll, legal and
computer services, costs of defending any lawsuits with any mortgagee, costs of selling, syndicating, financing, mortgaging or hypothecating any of Landlord’s interest in the Leased Premises, costs of any disputes between Landlord and its
employees (if any) whether or not engaged in Leased Premises operation, or outside fees paid in connection with disputes with other tenants, 

(iv) legal fees, space planners’ fees, real estate brokers’ leasing commissions, and advertising expenses incurred in connection
with leasing of the Leased Premises, 
 (v) costs for which Landlord is reimbursed by its insurance carrier or any tenant’s insurance
carrier, 
 (vi) any bad debt loss, rent loss or reserves for bad debts or rent loss, 

(vii) any interest or late fee resulting from any failure of Landlord to pay any item of Property Operating Expenses when it would have been
due without such interest or late fee; provided, however, that nothing herein shall be deemed from precluding Landlord from passing through to Tenant as a Property Operating Expense any cost associated with paying Property Operating Expenses on any
permitted installment or other periodic basis, even if such payment basis results in an increase in the Property Operating Expense in question, 

  
 40 

 Building C 
  

(viii) overhead and profit increment paid to Landlord or to subsidiaries or affiliates of Landlord for such services in the Leased Premises to
the extent the same exceeds the costs of such services rendered by unaffiliated third parties on a competitive basis (but the foregoing shall not limit Tenant’s obligation to pay the Management Fee described in Paragraph 13.12(b) above), 

(ix) costs of repairs or rebuilding necessitated by condemnation except as otherwise provided in this Lease, or the portion(s) of any
insurance deductibles that are excluded in Section 13.12(b)(i) above 
 (x) space planning fees and commissions, 

(xi) expenses for repairs, replacements or improvements to the extent such expenses are reimbursed by warranties from contractors,
manufacturers or suppliers, or are otherwise borne by parties other than Landlord, 
 (xii) repairs, alterations, additions, improvements
or replacements made pursuant to Paragraph 2.8, 
 (xiii) costs incurred due to Landlord’s violation of any terms and conditions of
this Lease, any other lease or occupancy agreement at the Project, any contract or agreement relating to the Project or any part thereof (including Restrictions), or of any law, ordinance or governmental rule or regulation affecting the Building,

 (xiv) costs of repairs or other work occasioned by casualty (to the extent the cost of the repairs is reimbursed by insurance), 

(xv) costs incurred to remove, remedy, contain or treat any Hazardous Materials, except to the extent that such costs arise in the ordinary
course of maintenance of an office building campus in the general locale of the Project or result from the acts or omissions of Tenant or any of Tenant’s Parties; provided, however, that nothing herein shall be deemed to modify or lessen the
obligations of Tenant pursuant to Section 4.11 of this Lease, 
 (xvi) reserves of any kind, 

(xvii) costs of rentals for items which if purchased, rather than rented, would constitute a capital improvement or equipment other than
Permitted Capital Expenditures; 
 (xviii) the following costs, expenses and fees to the extent incurred in connection with the initial
construction, entitlement and development of the Project: (A) all fees and costs attributable to compliance with Landlord’s conditions of approval for the Project (e.g., mitigation fees, impact fees, subsidies, tap-in fees, development
fees, connection fees or similar one-time charges or costs (however characterized), (B) lump sum assessments or payments under any public or private infrastructure payment districts, (C) costs of traffic studies, transportation management
reports, and establishment of transportation management plans, and (D) environmental impact reports, except that Property Maintenance Costs shall include (or such costs may be charged directly to Tenant, if applicable) any on-going operational
costs incurred by Landlord that are set forth in Landlord’s entitlements, permits or other approvals for the development of the Project, including but not limited to transportation management plans and/or the conditions of approval and
development agreement therefor, or any such ongoing operational costs of any future programs or requirements which are either referenced in such entitlements, permits or approvals or which are a logical evolution thereof and are subsequently
required by the governmental agencies implementing such entitlements, permits or approvals, 
 (xix) any payments under a ground lease
relating to the Project, Building or Leased Premises, 
 (xx) costs, including permit, license and inspection costs, incurred with respect
to the installation of other tenants’ or other occupants’ improvements made for other tenants or other occupants at the Project or incurred in renovating or otherwise improving, decorating, painting or redecorating space (excluding Common
Areas) for tenants or other occupants of the Project, 
 (xxi) any assessment and premiums for time periods other than the Lease Term (but
overlapping assessment or premium periods may be prorated and the amounts allocable to the lease term shall be included in Property Operating Costs), 

(xxii) marketing and promotional costs, including but not limited to leasing commissions, real estate brokerage commissions, and
attorneys’ fees in connection with the negotiation 

  
 41 

 Building C 
  

and preparation of letters, deal memos, letters of intent, leases, subleases and/or assignments, space planning costs, and other costs and expenses incurred in connection with lease, sublease
and/or assignment negotiations and transactions with present or prospective tenants or other occupants of the Project, including Tenant (but no costs arising from Article 7 shall be excluded by this subparagraph), 

(xxiii) costs of services, utilities, or other benefits which are not offered to Tenant or for which Tenant is charged for directly but which
are provided to another tenant or occupant of the Project, including, but not limited to, above Building standard heating, ventilation and air-conditioning, and janitorial services, 

(xxiv) all items and services for which Tenant or any other tenant at the Project reimburses Landlord or pays directly (as opposed to paying
the same through Tenant’s Building Share or Tenant’s Project Share or any other tenant’s share of Property Operating Costs), including electric power or other utility costs for which any tenant directly contracts with the local public
service company, 
 (xxv) advertising and promotional expenditures, including but not limited to tenant newsletters and Project or Building
promotional gifts, events or parties for existing or potential future occupants, and the costs of signs (other than the Building directory) in or on the Project identifying the owner of the Building or other tenants’ signs; 

(xxvi) any cost or expense arising solely in connection with the initial entitlement, development, and construction of the Other Buildings;

 (xxvii) any cost which is expressly excluded from Property Operating Expenses, Real Property Taxes, or Property Maintenance Costs
pursuant to a different provision of this Lease. 
 (xxviii) costs, other than those incurred in ordinary maintenance and repair, for
sculpture, paintings, fountains or other objects of art, 
 (xxix) costs (including in connection therewith all attorneys’ fees and
costs of settlement judgments and payments in lieu thereof) arising from claims, disputes or potential disputes in connection with potential or actual claims, litigation or arbitrations pertaining to Landlord and/or the Building, the Other Buildings
and/or the Project; 
 (xxx) the cost of any work or services performed for any tenant (including Tenant) at such tenant’s cost for
which Landlord has been reimbursed, 
 (xxxi) payments to Landlord or to subsidiaries or affiliates of Landlord for services in the
Building to the extent the same exceeds the fair market costs of such services rendered by unaffiliated comparable third parties, 

(xxxii) the cost of any parties, ceremonies or other events for tenants, Landlord, Landlord’s affiliates or third parties, whether
conducted in the Building, the Project or in any other location; 
 (xxxiii) costs incurred by Landlord in connection with rooftop
communications equipment of Landlord or other persons, tenants or occupants on the Building or the Project; 
 (xxxiv) “takeover”
expenses, including, but not limited to, the expenses incurred by Landlord with respect to space located in another building of any kind or nature in connection with the leasing of space in the Building, 

(xxxv) any costs, fees, dues, contributions or similar expenses for industry associations or similar organizations, and Landlord’s
charitable or political contributions, 
 (xxxvi) any costs associated with the purchase or rental or furniture, fixtures or equipment for
any management, security, engineering, or other offices associated with the Project and Common Areas (other than the Cafe & Fitness Center) or for Landlord’s offices or the offices of other landlords of the Project or for the Common
Areas of the Building or Project, 
 (xxxvii) wages, fees, operating expenses and taxes incurred in connection with the ownership,
management and operation of commercial concessions operated by Landlord, 
 (xxxviii) the entertainment expenses and travel expenses of
Landlord, its employees, agents, partners and affiliates, 
 (xxxix) any costs for which Landlord has been reimbursed or receives a credit
or refund or to the extent of any discount, provided if Landlord receives the same in connection with any costs or expenditures previously included in Property Operating Expenses for an expense year, Landlord shall promptly reimburse Tenant for any
overpayment for such previous expense year; and 

  
 42 

 Building C 
  

(xl) all items and services for which Tenant or any other tenant at the Project reimburses Landlord or pays directly (as opposed to paying the
same through Tenant’s Building Share or Tenant’s Project Share or any other tenant’s share of Property Operating Costs), including electric power or other utility costs for which any tenant directly contracts with the local public
service company, and 
 (xli) the costs of obtaining any initial LEED certification of the Building; provided, however, that nothing herein
shall be deemed to prevent Landlord from including in Property Operating Costs any subsequent costs of complying with the operational requirements of that LEED certification. 

It is understood that Property Maintenance Expenses shall be calculated net of all cash discounts, trade discounts, or quantity discounts received by Landlord
or Landlord’s managing agent in the purchase of any goods, utilities, or services which are the basis of the specific Property Maintenance Expense. In the calculation of any expenses hereunder, it is understood that Landlord will not charge
Tenant more than one hundred percent (100%) of any Property Maintenance Expenses due hereunder. Landlord and Tenant also agree that it is their intention that no Property Maintenance Expenses (or exclusions therefrom be duplicated. 

(e) Law. The term “Law” or “Laws” shall mean any judicial decisions and any statute, constitution,
ordinance, resolution, regulation, rule, code, administrative order, condition of approval, or other requirements of any municipal, county, state, federal, or other governmental agency or authority having jurisdiction over the parties to this Lease,
the Leased Premises, the Building, the Property, or the Project, or any of them, in effect either at the Effective Date of this Lease or at any time during the Lease Term, including, without limitation, any regulation, order, or policy of any
quasi-official entity or body (e.g. a board of fire examiners or a public utility or special district). Except to the extent otherwise expressly provided in this Lease, to the extent any Law or Restriction places limits on the Building or any
portion thereof, or on the Property or the Project or any portion thereof, such limits shall be equitably allocated to the Leased Premises pro rata in the same proportion that the rentable square footage of the Leased Premises bears to the rentable
square footage of the applicable Building or portion thereof, or the Property or the Project or portion thereof, as applicable. 
 (f)
Lender. The term “Lender” shall mean the holder of any promissory note or other evidence of indebtedness secured by the Property or any portion thereof. 

(g) Rent. The term “Rent” shall mean collectively Base Monthly Rent and all Additional Rent. 

(h) Restrictions. The term “Restrictions” shall mean (as they may exist from time to time) any and all covenants,
conditions and restrictions, private agreements, easements, and any other recorded documents or instruments affecting the use of the Property, the Building, the Leased Premises, or the Common Areas; provided, however, that the Required Conditions
(as defined in Paragraph 2.2(a) of this Lease) must be satisfied with respect to any future Restrictions imposed by Landlord (as opposed to those which may be imposed by a governmental or quasi-governmental agency). 

13.13 General Waivers. One party’s consent to or approval of any act by the other party requiring the first party’s consent
or approval shall not be deemed to waive or render unnecessary the first party’s consent to or approval of any subsequent similar act by the other party. No waiver of any provision hereof, or any waiver of any breach of any provision hereof,
shall be effective unless in writing and signed by the waiving party. The receipt by Landlord of any rent or payment with or without knowledge of the breach of any other provision hereof shall not be deemed a waiver of any such breach. No waiver of
any provision of this Lease shall be deemed a continuing waiver unless such waiver specifically states so in writing and is signed by both Landlord and Tenant. No delay or omission in the exercise of any right or remedy accruing to either party upon
any breach by the other party under this Lease shall impair such right or remedy or be construed as a waiver of any such breach theretofore or thereafter occurring. The waiver by either party of any breach of any provision of this Lease shall not be
deemed to be a waiver of any subsequent breach of the same or any other provisions herein contained. 
 13.14 Miscellaneous. Should
any provisions of this Lease prove to be invalid or illegal, such invalidity or illegality shall in no way affect, impair or invalidate any other provisions hereof, and such remaining provisions shall remain in full force and effect. Time is of the
essence with respect to the performance of every provision of this Lease in which time of performance is a factor. Any copy of this Lease which is executed by the parties shall be deemed an original for all purposes. This Lease shall, subject to the
provisions regarding assignment, apply to and bind the respective heirs, successors, executors, administrators and assigns of Landlord and Tenant. The term “party” shall mean Landlord or Tenant as the context implies. If Tenant
consists of more than one person or entity, then all members of 

  
 43 

 Building C 
  

Tenant shall be jointly and severally liable hereunder. If this Lease is signed by an individual “doing business as “ or “dba” another person or entity or entity
name, the individual who signs this Lease will be deemed to be the Tenant hereunder for all purposes. Submission of this Lease for review, examination or signature by Tenant does not constitute an offer to lease, a reservation of or an option for
lease, or a binding agreement of any kind, and notwithstanding any inconsistent language contained in any other document, this Lease is not effective as a lease or otherwise until execution and delivery by both Landlord and Tenant, and prior to such
mutual execution and delivery, neither party shall have any obligation to negotiate and may discontinue discussions and negotiations at any time for any reason or no reason. This Lease shall be construed and enforced in accordance with the Laws of
the State in which the Leased Premises are located. The headings and captions in this Lease are for convenience only and shall not be construed in the construction or interpretation of any provision hereof. When the context of this Lease requires,
the neuter gender includes the masculine, the feminine, a partnership, corporation, limited liability company, joint venture, or other form of business entity, and the singular includes the plural. The terms “must,” “shall,”
“will,” and “agree” are mandatory. The term “may” is permissive. The term “governmental agency” or “governmental authority” or similar terms shall include, without limitation, all
federal, state, city, local and other governmental and quasi-governmental agencies, authorities, bodies, boards, etc., and any party or parties (other than Landlord or a Landlord affiliate) having enforcement rights under any Restrictions. When a
party is required to do something by this Lease, it shall do so at its sole cost and expense without right of reimbursement from the other party unless specific provision is made therefor. Where Landlord’s consent is required hereunder, it
shall be reasonable for any such consent to be withheld until Landlord’s receipt of the consent of any Lender, if and to the extent Landlord is required to obtain such Lender’s consent. Landlord and Tenant shall both be deemed to have
drafted this Lease, and the rule of construction that a document is to be construed against the drafting party shall not be employed in the construction or interpretation of this Lease. Where Tenant is obligated not to perform any act or is not
permitted to perform any act, Tenant is also obligated to restrain any others reasonably within its control, including agents, invitees, contractors, subcontractors and employees, from performing such act. Landlord shall not become or be deemed a
partner or a joint venturer with Tenant by reason of any of the provisions of this Lease. 
 13.15 Further Development and
Subdivision. Notwithstanding anything to the contrary contained herein, Landlord itself and through its agents, employees and contractors shall be entitled to sell one or more parcels or buildings located on the Project, and to further improve
the Project, including by constructing additional buildings and a parking structure, in the event that Landlord or its affiliate has or obtains the legal right to further develop the Project, either alone or in connection with acquiring property
adjacent to the Project. Such sale and development efforts by Landlord may include, without limitation, the relocation, restriping, or reconfiguration of the parking areas so long as the Required Conditions are satisfied, application for building
permits use permits, and other development approvals, parcelization, lot combination or merger, or lot line adjustment of the Property or Project, and construction of buildings and parking structures. Tenant agrees to execute such reasonable
documents and take such actions as reasonably necessary to assist Landlord with such efforts and actions, provided such documents do not materially increase Tenant’s obligations or materially diminish Tenant’s rights under the Lease.
Tenant agrees that such efforts and actions of Landlord shall not constitute constructive eviction of Tenant from the Project, the Property, or the Leased Premises. Following any parcelization, lot combination or merger, or lot line adjustment of
the Property or the Project, Landlord and Tenant agree to amend this Lease to conform the descriptions of the Property, Project, Site Plan, and Common Areas, and (subject to there being no decrease in the number of parking spaces to which Tenant is
entitled) the parking areas contained herein, to the parcelization, lot combination or merger, lot line adjustment, or reconfiguration. Landlord agrees to minimize the disruption of Tenant’s use of the Leased Premises, the Building, the Common
Areas and the Project to the extent reasonable, given Landlord’s efforts and actions described herein. In connection with any sale or subdivision of a portion of the Project, Landlord may amend the description of the Common Areas, so long as
the Required Conditions are satisfied. 
 13.16 Patriot Act Compliance. 

(a) Tenant will use its good faith and commercially reasonable efforts to comply with the Patriot Act (as defined below) and all applicable
requirements of governmental authorities having jurisdiction over Tenant, the Property, or the Project, including those relating to money laundering and terrorism. Landlord shall have the right to audit Tenant’s compliance with the Patriot Act
and all applicable requirements of governmental authorities having jurisdiction over Tenant, the Property, or the Project, including those relating to money laundering and terrorism. In the event that Tenant fails to comply with the Patriot Act or
any such requirements of governmental authorities, then Landlord may, at its option, cause Tenant to comply therewith and any and all reasonable costs and expenses incurred by Landlord in connection therewith shall be deemed Additional Charges and
Rent and shall be immediately due and payable. For purposes hereof, the term “Patriot Act” means the Uniting and Strengthening America by Providing Appropriate Tools Required to Intercept and Obstruct Terrorism (USA PATRIOT ACT) Act
of 2001, as the same may be amended from time to time, and corresponding provisions of future laws. 

  
 44 

 Building C 
  

(b) Neither Tenant nor any partner in Tenant or member of such partner nor any owner of a direct or indirect interest in Tenant (a) is
listed on any Government Lists (as defined below), (b) is a person who has been determined by competent authority to be subject to the prohibitions contained in Presidential Executive Order No. 13224 (Sept. 23, 2001) or any other similar
prohibitions contained in the rules and regulations of OFAC (as defined below) or in any enabling legislation or other Presidential Executive Orders in respect thereof, (c) has been previously indicted for or convicted of any felony involving a
crime or crimes of moral turpitude or for any Patriot Act Offense (as defined below), or (d) is currently under investigation by any governmental authority for alleged criminal activity. For purposes hereof, the term “Patriot Act
Offense” means any violation of the criminal laws of the United States of America or of any of the several states, or that would be a criminal violation if committed within the jurisdiction of the United States of America or any of the
several states, relating to terrorism or the laundering of monetary instruments, including any offense under (a) the criminal laws against terrorism; (b) the criminal laws against money laundering, (c) the Bank Secrecy Act, as amended,
(d) the Money Laundering Control Act of 1986, as amended, or the (e) Patriot Act. “Patriot Act Offense” also includes the crimes of conspiracy to commit, or aiding and abetting another to commit, a Patriot Act Offense. For
purposes hereof, the term “Government Lists” means (i) the Specially Designated Nationals and Blocked Persons Lists maintained by Office of Foreign Assets Control (“OFAC”), (ii) any other list of
terrorists, terrorist organizations or narcotics traffickers maintained pursuant to any of the Rules and Regulations of OFAC or pursuant to any Executive Order of the President of the United States of America. 

13.17 Restrictions on Leasing to Certain Competitors. Provided that and for so long as (a) Tenant is Aruba Networks, Inc. [NASDAQ:
ARUN] or a Permitted Transferee, (b) it is occupancy of at least one (1) full floor of the Building and five (5) full floors of Building D, and (c) it is not in a monetary or a material non-monetary default under this Lease with
respect to which Landlord is exercising remedies pursuant to the California Civil Code, then during the Lease Term (as the same may be extended pursuant to Article 15 below), Landlord shall not, without Tenant’s approval, lease space
(i) in the Building or Building A, Building B, or Building D to Cisco Systems, Inc., Aerohive Networks, Inc., or Ruckus Wireless, Inc., and (ii) in the Building or Building D to Huawei Technologies Co. Ltd., Meraki, Inc., Ubiquiti
Networks, Inc., or Meru Networks, Inc. Notwithstanding the foregoing, it shall not constitute a breach of this Paragraph 13.17 if any tenants of the Project assign or sublease to any of the foregoing companies, nor if Landlord extends the lease of a
tenant so acquired or permits the expansion of space leased thereunder. In addition, this provision shall not apply to a tenant who is acquired by one of these companies whether or not it remains a separate company or is merged into the acquirer.

 ARTICLE 14 
 LEGAL
AUTHORITY 
 BROKERS AND ENTIRE AGREEMENT 

14.1 Legal Authority. Each of Landlord and Tenant hereby represents and warrants to the other that it is validly formed and duly
authorized and existing, that it is qualified to do business in the State in which the Leased Premises are located, that it has the full right and legal authority to enter into this Lease, and that such party’s signatory(ies) are duly
authorized to execute and deliver this Lease on behalf of such party. Tenant shall, within ten (10) days after the Effective Date of this Lease, deliver to Landlord a certified copy of the resolution of its board of directors authorizing or
ratifying the execution of this Lease. Landlord shall, within ten (10) days after the Effective Date of this Lease, deliver to Tenant an original or a certified copy of the resolution of its Members authorizing or ratifying the execution of
this Lease. 
 14.2 Brokerage Commissions.  

(a) Tenant represents, warrants and agrees that it has not had any dealings with any real estate broker(s), leasing agent(s), finder(s) or
salesmen, other than the Brokers (as named in Article 1) with respect to the lease by it of the Leased Premises pursuant to this Lease, and that it will indemnify, defend with competent counsel, and hold Landlord harmless from any liability for the
payment of any real estate brokerage commissions, leasing commissions or finder’s fees claimed by any other real estate broker(s), leasing agent(s), finder(s), or salesmen to be earned or due and payable by reason of Tenant’s agreement or
promise (implied or otherwise) to pay (or to have Landlord pay) such a commission or finder’s fee by reason of its leasing the Leased Premises pursuant to this Lease. 

(b) Landlord represents, warrants and agrees that it has not had any dealings with any real estate broker(s), leasing agent(s), finder(s) or
salesmen, other than the Brokers (as named in Article 1) with respect to the lease by it of the Leased Premises pursuant to this Lease, and that it will indemnify, defend with competent counsel, and hold Tenant harmless from any liability for the
payment of any real estate brokerage commissions, leasing commissions or finder’s fees claimed by any other real estate broker(s), leasing agent(s), finder(s), or salesmen to be earned or due and payable by reason of Landlord’s agreement
or promise (implied or otherwise) to pay (or to have Tenant pay) such a commission or finder’s fee by reason of its leasing the Leased Premises pursuant to this Lease. 

  
 45 

 Building C 
  

(c) Landlord shall pay the Brokers a commission pursuant to a separate agreement between Landlord and each Broker. 

(d) Notwithstanding any provision of this Lease to the contrary, Landlord is not obligated to pay any leasing commission or compensation of
any kind or type in connection with an extension of the term of this Lease, an expansion of the Leased Premises, a lease or sublease of any other premises leased by Tenant pursuant to any right of first offer or right of first refusal or other
similar right granted to Tenant, unless such obligation is set forth in the separate agreements between Landlord and each Broker described above. 

14.3 Entire Agreement. This Lease and the Exhibits (as described in Article 1), which Exhibits are by this reference incorporated
herein, constitute the entire agreement between the parties, and there are no other agreements, understandings or representations between the parties relating to the lease by Landlord of the Leased Premises to Tenant, except as expressed herein. No
subsequent changes, modifications or additions to this Lease shall be binding upon the parties unless in writing and signed by both Landlord and Tenant. 

14.4 Landlord’s Representations. Tenant acknowledges that neither Landlord nor any of its agents made any representations or
warranties respecting the Property, the Building or the Leased Premises, upon which Tenant relied in entering into the Lease, which are not expressly set forth in this Lease. Tenant further acknowledges that neither Landlord nor any of its agents
made any representations as to (i) whether the Leased Premises may be used for Tenant’s intended use under existing Law, or (ii) the suitability of the Leased Premises for the conduct of Tenant’s business, or (iii) the exact
square footage of the Leased Premises or the Building, and that Tenant relies solely upon its own investigations with respect to such matters. Tenant expressly waives any and all claims for damage by reason of any statement, representation,
warranty, promise or other agreement of Landlord or Landlord’s agent(s), if any, not contained in this Lease or in any Exhibit attached hereto. 

ARTICLE 15 
 OPTIONS TO
EXTEND 
 15.1 Options to Extend. So long as Aruba Networks, Inc. or a Permitted Assignee is the Tenant hereunder and occupies
the entirety of the initial Leased Premises consisting of the first floor of the Building, and subject to the conditions set forth below, Tenant shall have two options to extend the term of this Lease with respect to the Leased Premises, the first
for a period of five (5) years from the expiration of the initial, unextended Lease Term (the “First Extension Period”), and the second (the “Second Extension Period”) for a period of five (5) years from
the expiration of the First Extension Period, subject to the following conditions: 
 (a) Each option to extend shall be exercised, if at
all, by notice of exercise given to Landlord by Tenant not more than twelve (12) months nor less than nine (9) months prior to the expiration of the initial, unextended Lease Term or the expiration of the First Extension Period, as
applicable; 
 (b) Anything herein to the contrary notwithstanding, if Tenant is in monetary or material non-monetary default under any of
the terms, covenants or conditions of this Lease, either at the time Tenant exercises either extension option or on the commencement date of the First Extension Period or the Second Extension Period, as applicable, Landlord shall have, in addition
to all of Landlord’s other rights and remedies provided in this Lease, the right to terminate such option(s) to extend upon notice to Tenant within five (5) business days after receipt of Tenant’s extension notice or else Landlord
shall be deemed to have waived Landlord’s right to terminate such option. For the avoidance of confusion, the foregoing shall not be read to prevent Tenant from curing the applicable default and then exercising the applicable option to extend
once the default is cured if such cure is completed within the applicable cure period, if any, expressly set forth in this Lease. 
 15.2
Fair Market Rent. In the event the applicable option is exercised in a timely fashion, the Lease shall be extended for the term of the applicable extension period upon all of the terms and conditions of this Lease, provided that the Base Monthly
Rent applicable to each extension period shall be 95% of the “Fair Market Rent” for the Leased Premises. For purposes hereof, “Fair Market Rent” shall mean the initial Base Monthly Rent for each extension period and any
escalations thereto, as determined with reference to the then-prevailing rates for recently negotiated direct leases (i.e., not subleases) in comparable 2007 or newer steel frame buildings of four (4) or more stories in the cities of Santa
Clara or Sunnyvale (but not taking into account Tenant’s furniture, fixtures, or equipment, or any above-standard tenant improvements made by Tenant at its sole cost), pursuant to the process described below. Except to the extent set forth in a
separate written agreement between Landlord and such broker, no leasing commissions shall be due or payable to any broker retained by Tenant with regard to this Lease for any Extension Period. 

  
 46 

 Building C 
  

15.3 Tenant’s Election. Within thirty (30) days after receipt of Tenant’s notice of exercise, Landlord shall notify
Tenant in writing of Landlord’s estimate of the Base Monthly Rent for the applicable extension period, based on the provisions of Paragraph 15.2 above. Within thirty (30) days after receipt of such notice from Landlord, Tenant shall have
the right either to (i) accept Landlord’s statement of Base Monthly Rent as the Base Monthly Rent for the applicable extension period; or (ii) elect to arbitrate Landlord’s estimate of Fair Market Rent, such arbitration to be
conducted pursuant to the provisions hereof. Failure on the part of Tenant to require arbitration of Fair Market Rent within such thirty (30) day period shall constitute acceptance of the Base Monthly Rent for the applicable extension period as
calculated by Landlord. If Tenant elects arbitration, the arbitration shall be concluded within ninety (90) days after the date of Tenant’s election, subject to extension for an additional thirty (30) day period if a third arbitrator
is required and does not act in a timely manner. To the extent that arbitration has not been completed prior to the expiration of any preceding period for which Base Monthly Rent has been determined, Tenant shall pay Base Monthly Rent at a rate
equal to 102.5% of the Monthly Base Rent due for the last month of the initial Lease Term or First Extension Period, as relevant, with the potential for an adjustment to be made once Fair Market Rent is ultimately determined by arbitration. 

 15.4 Rent Arbitration. In the event of arbitration, the judgment or the award rendered in any such arbitration may be entered
in any court having jurisdiction and shall be final and binding between the parties. The arbitration shall be conducted and determined in the City and County of Santa Clara in accordance with the then prevailing rules of JAMS or its successor for
arbitration of commercial disputes except to the extent that the procedures mandated by such rules shall be modified as follows:  

(a) Tenant shall make demand for arbitration in writing within thirty (30) days after service of Landlord’s determination of Fair
Market Rent given under Paragraph 15.3 above, specifying therein the name and address of the person to act as the arbitrator on its behalf. The arbitrator shall be qualified as a real estate appraiser or broker familiar with the Fair Market Rent of
comparable buildings in the Santa Clara or Sunnyvale area who would qualify as an expert witness over objection to give opinion testimony addressed to the issue in a court of competent jurisdiction. Failure on the part of Tenant to make a proper
demand in a timely manner for such arbitration shall constitute a waiver of the right thereto. Within fifteen (15) days after the service of the demand for arbitration, Landlord shall give notice to Tenant, specifying the name and address of
the person designated by Landlord to act as arbitrator on its behalf who shall be similarly qualified. If Landlord fails to notify Tenant of the appointment of its arbitrator, within or by the time above specified, then the arbitrator appointed by
Tenant shall be the arbitrator to determine the issue. 
 (b) In the event that two arbitrators are chosen pursuant to Paragraph 15.4(a)
above, the arbitrators so chosen shall, within fifteen (15) days after the second arbitrator is appointed determine the Fair Market Rent. If the two arbitrators shall be unable to agree upon a determination of Fair Market Rent within such
fifteen (15) day period, they, themselves, shall appoint a third arbitrator, who shall be a competent and impartial person with qualifications similar to those required of the first two arbitrators pursuant to Paragraph 15.4(a). In the event
they are unable to agree upon such appointment within seven (7) days after expiration of such fifteen (15) day period, the third arbitrator shall be selected by the parties themselves, if they can agree thereon, within a further period of
fifteen (15) days. If the parties do not so agree, then either party, on behalf of both, may request appointment of such a qualified person by the then Presiding Judge of the California Superior Court having jurisdiction over the County of
Santa Clara, and the other party shall not raise any question as to such Judge’s full power and jurisdiction to entertain the application for and make the appointment. The three arbitrators shall decide the dispute if it has not previously been
resolved by following the procedure set forth below. 
 (c) Where an issue cannot be resolved by agreement between the two arbitrators
selected by Landlord and Tenant or settlement between the parties during the course of arbitration, the issue shall be resolved by the three arbitrators within fifteen (15) days of the appointment of the third arbitrator in accordance with the
following procedure. The arbitrator selected by each of the parties shall state in writing his determination of the Fair Market Rent supported by the reasons therefor with counterpart copies to each party. The arbitrators shall arrange for a
simultaneous exchange of such proposed resolutions. The role of the third arbitrator shall be to select which of the two proposed resolutions most closely approximates his determination of Fair Market Rent. The third arbitrator shall have no right
to propose a middle ground or any modification of either of the two proposed resolutions. The resolution he chooses as most closely approximating his determination shall constitute the decision of the arbitrators and be final and binding upon the
parties. 
 (d) In the event of a failure, refusal or inability of any arbitrator to act, his successor shall be appointed by him, but in
the case of the third arbitrator, his successor shall be appointed in the same manner as provided for appointment of the third arbitrator. The arbitrators shall decide the issue within fifteen (15) days after the appointment of the third
arbitrator. Any decision in which the arbitrator appointed by Landlord and the arbitrator appointed by Tenant concur shall be binding and conclusive upon the parties. Each party shall pay the fee and expenses of its respective arbitrator and both
shall share the fee and expenses of the third arbitrator, if any, and the attorneys’ fees and expenses of counsel for the respective parties and of witnesses shall be paid by the respective party engaging such counsel or calling such witnesses.

  
 47 

 Building C 
  

(e) The arbitrators shall have the right to consult experts and competent authorities to obtain factual information or evidence pertaining to a
determination of Fair Market Rent, but any such consultation shall be made in the presence of both parties with full right on their part to cross examine. The arbitrators shall render their decision and award in writing with counterpart copies to
each party. The arbitrators shall have no power to modify the provisions of this Lease. 
 ARTICLE 16 

TELEPHONE SERVICE 

Notwithstanding any other provision of this Lease to the contrary: 

(i) Landlord shall have no responsibility for providing to Tenant any telephone equipment, including wiring, within the Leased Premises or
for providing telephone service or connections from the utility to the Leased Premises; and 
 (ii) Landlord makes no warranty as to the
quality, continuity or availability of the telecommunications services in the Building, and Tenant hereby waives any claim against Landlord for any actual or consequential damages (including damages for loss of business) in the event Tenant’s
telecommunications services in any way are interrupted, damaged or rendered less effective, except to the extent caused by the active gross negligence or willful misconduct of Landlord, its agents or employees. Tenant accepts the telephone equipment
(including, without limitation, the intra-building network cable (“INC”)) in its AS-IS condition, and Tenant shall be solely responsible for contracting with a reliable third party vendor to assume responsibility for the maintenance
and repair thereof (which contract shall contain provisions requiring such vendor to inspect the INC periodically (the frequency of such inspections to be determined by such vendor based on its experience and professional judgment), and requiring
such vendor to meet local and federal requirements for telecommunications material and workmanship). Landlord shall not be liable to Tenant and Tenant waives all claims against Landlord whatsoever, whether for personal injury, property damage, loss
of use of the Leased Premises, or otherwise, due to the interruption or failure of telephone services to the Leased Premises. 
 (iii) All
costs incurred by Landlord for the installation, maintenance, repair and replacement of telephone wiring in the Building, if Landlord in its sole discretion elects to do so, shall be a Property Maintenance Cost. 

ARTICLE 17 
 RIGHT OF
FIRST REFUSAL TO LEASE; RIGHT OF FIRST OFFER TO LEASE 
 17.1 Right of First Refusal to Lease. Subject to the rights of any
company which executes a lease for space in the Project pursuant to a term sheet or letter of intent executed prior to the Effective Date of this Lease: 

(a) Provided that at the time Landlord would otherwise be obligated to deliver a ROFR Notice (as hereinafter defined), Tenant is Aruba
Networks Inc. (or a Permitted Transferee) and is then leasing the entire first floor of the Building and has not received written notice from Landlord informing Tenant that it is in monetary or material non-monetary default under this Lease which is
then currently uncured, then after receiving or negotiating an Acceptable Proposal (as defined below) for any portion (the “Identified ROFR Space”) of the second floor or the third floor of the Building, but not involving any
portion of any of the Other Buildings (such second and third floors in such event being defined as the “Available ROFR Space”), Landlord shall deliver a written notice (the “ROFR Notice”) to Tenant and the terms of
the Acceptable Proposal. Anything in this Lease to the contrary notwithstanding, Tenant shall not have the right to deliver Tenant’s Election Notice (as hereinafter defined) during any period that Tenant is in a monetary or material
non-monetary default under any of the terms, covenants or conditions of this Lease with respect to which it has received a written notice from Landlord if such default remains uncured, and the time periods provided for herein shall not be tolled or
extended during Tenant’s cure thereof. 
 (b) Tenant shall notify Landlord in writing within five (5) business days after receipt
of the ROFR Notice of Tenant’s election to lease the Identified ROFR Space on the economic terms set forth in the Acceptable Proposal (“Tenant’s Election Notice”). Tenant shall not have the right to lease less than the
entire Identified ROFR Space. If any proposal Landlord receives includes any space in any of the Other Buildings, Landlord shall be free to negotiate such proposal with the party who delivered it, and this Paragraph 17.1 shall not apply in any way
thereto. As used herein, the term “Acceptable Proposal” means a lease proposal received from or negotiated with a bona fide, unaffiliated third party (whether or not executed) containing terms upon which Landlord is willing to lease
the Identified ROFR Space to such third party. In addition, and notwithstanding the foregoing, Tenant acknowledges that the existing tenant of the fourth floor of the Building has prior rights to lease all or portions of the third floor 

  
 48 

 Building C 
  

of the Building, and therefore the Acceptable Proposal as it relates to the third floor of the Building, and Tenant’s right to provide Tenant’s Election Notice with respect to the third
floor of the Building, are each subject and subordinate to the rights of the fourth floor tenant. 
 (c) Failure of Tenant to deliver
Tenant’s Election Notice within the required time period (i) shall be deemed an election by Tenant to not lease the Identified ROFR Space, Landlord shall then be free to lease the Identified ROFR Space to a third party in accordance with
the economic terms set forth in the ROFR Notice or such terms as Landlord shall elect and Tenant shall have no further rights to lease the Identified ROFR Space thereafter, and this Paragraph 17.1 shall terminate and be of no further force or
effect; provided, however, that (i) Tenant’s rights under this Paragraph 17.1 shall continue for any portion of the Available ROFR Space contiguous to the Leased Premises (as the same may have previously been expanded) which was not
referenced in the ROFR Notice, (ii) Tenant’s rights under this Paragraph 17.1 with respect to the Identified ROFR Space shall continue to the extent such space becomes available for lease again during the Lease Term or any extension
thereof and is contiguous to the Leased Premises (as the same may have previously been expanded), and (iii) in the event that Landlord proposes to lease such Identified ROFR Space at a Net Effective Rental Rate that is less (on a per rentable
square foot basis) than ninety percent (90%) of the Net Effective Rental Rate specified in the ROFR Notice, Tenant’s rights under this Paragraph 17.1 shall be revived as to the Identified ROFR Space and Landlord shall deliver a revised
ROFR Notice (the “Revised ROFR Notice”) offering such Identified ROFR Space to Tenant at such proposed lower rate and Tenant shall have the right to lease such Identified ROFR Space on the terms set forth in such Revised ROFR Notice
by notice to Landlord given within five (5) business days after Tenant’s receipt thereof. As used in this Agreement, the term “Net Effective Rental Rate” shall mean the net present value of the rent and additional rent
payable under the ROFR Notice, taking into account any allowances and the fair market value of any work to be performed by Landlord at its expense in connection with any such proposed transaction using a discount rate equal to the Prime Rate plus
two percent (2%) as reported in the Wall Street Journal from time to time, or any successor published from time to time as reasonably selected by Landlord. 

(d) If Tenant delivers Tenant’s Election Notice within the time period required herein, Tenant shall be bound and obligated to lease from
Landlord, and Landlord shall be bound and obligated to lease to Tenant, the Identified ROFR Space on the terms set forth in the ROFR Notice, and for record-keeping purposes, Landlord and Tenant shall enter into an amendment of this Lease to include
the Identified ROFR Space within fifteen (15) business days after Landlord’s receipt of Tenant’s Election Notice. The economic terms (including, without limitation, the amount of rent and the tenant improvement allowance, if any)
shall be the terms set forth in the ROFR Notice, and conforming changes shall be made as necessary or desirable to increase the rentable square footage of the Leased Premises, as well as to any other provisions that are a function of the rentable
square footage of the Leased Premises (e.g., Tenant’s Building Share and Tenant’s Project Share, and actual number of parking spaces allocated to Tenant based upon the ratio set forth in the “Parking” Paragraph of Article 1
above). If Tenant has received written notice from Landlord that Tenant is in a monetary or material non-monetary default under any of the terms, covenants or conditions of this Lease and such default remains uncured after the expiration of the
relevant cure period, Landlord shall have, in addition to all of Landlord’s other rights and remedies provided in this Lease, the right to terminate the right of first refusal contained herein upon notice to Tenant. 

17.2 Right of First Offer to Lease.  

(a) In the event that Tenant does not lease the entire Available ROFR Space pursuant to Paragraph 17.1 above, Landlord shall be free to lease
all or any portion of such space not leased pursuant to Paragraph 17.1 above, to other prospective tenants (the “Initial Lease-Up”). At any time after any of the leases of the Available ROFR Space entered into by Landlord and such
other tenant(s) expire and are not extended or renewed, whether pursuant to a right contained in such lease(s) or pursuant to negotiation, and provided that Tenant is then leasing the entire two (2) floors of the Leased Premises and has not
received written notice from Landlord informing Tenant that it is in monetary or material non-monetary default under this Lease which default is still uncured, when any Available ROFR Space which was the subject of such expired lease(s) becomes
available which Landlord desires to market for lease (the “Designated ROFO Space”), Landlord shall deliver a written notice (the “ROFO Notice”) to Tenant setting forth the Designated ROFO Space and the terms upon
which Landlord is intending to market the Designated ROFO Space. Tenant shall notify Landlord in writing with five (5) business days after receipt of the ROFO Notice of Tenant’s election to lease the Designated ROFO Space on the terms set
forth in the ROFO Notice (“Tenant’s ROFO Election Notice”). 
 (b) Failure of Tenant to deliver Tenant’s ROFO
Election Notice within the required time period shall be deemed an election by Tenant to not lease the Designated ROFO Space, Landlord shall be free to market the applicable Designated ROFO Space to third parties on such terms as Landlord shall
elect, and Tenant shall have no further right to lease the applicable Designated ROFO Space; provided, however, that, in the event that Landlord proposes to lease such Designated ROFO Space at a Net Effective Rental Rate that is less (on a per
rentable square foot basis) than ninety percent (90%) of the 

  
 49 

 Building C 
  

Net Effective Rental Rate specified in the ROFO Notice, Tenant’s rights under this Paragraph 17.2 shall be revived and Landlord shall deliver a revised ROFO Notice (the “Revised ROFO
Notice”) offering such Designated ROFO Space to Tenant at such proposed lower rate and Tenant shall have the right to lease such Designated ROFO Space on the terms set forth in such Revised ROFO Notice by notice to Landlord given within ten
(10) business days after Tenant’s receipt thereof. As used in this Agreement, the term “Net Effective Rental Rate” shall mean the net present value of the rent and additional rent payable under the ROFO Notice, taking into
account any allowances and the fair market value of any work to be performed by Landlord at its expense in connection with any such proposed transaction using a discount rate equal to the Prime Rate plus two percent (2%) as reported in the Wall
Street Journal from time to time, or any successor published from time to time as reasonably selected by Landlord. 
 (c) In the event
Tenant delivers Tenant’s ROFO Election Notice within the time period required herein, Tenant shall be bound and obligated to lease from Landlord, and Landlord shall be bound and obligated to lease to Tenant, the Designated ROFO Space on the
terms hereinafter described, and for record-keeping purposes, Landlord and Tenant shall enter into an amendment of this Lease to include the Designated ROFO Space within ten (10) business days after Landlord’s receipt of Tenant’s ROFO
Election Notice. The per square foot economic terms (including, without limitation, the amount of rent and the tenant improvement allowance, if any) shall be the terms set forth in the ROFO Notice and shall apply to the entire space constituting the
Designated ROFO Space (but the term shall be treated as set forth hereinafter), and conforming changes shall be made as necessary or desirable to increase the rentable square footage of the Leased Premises, as well as to any other provisions that
are a function of the rentable square footage of the Leased Premises (e.g., Tenant’s Building Share and Tenant’s Project Share). The Lease Expiration Date for the entirety of the Leased Premises, including the Designated ROFO Space, shall
be the date set forth in Article 1 above, as the same may be extended by Tenant for the First Extension Period and Second Extension Period pursuant to Article 15 above. 

(d) Anything herein to the contrary notwithstanding, if Tenant is in monetary or material non-monetary default under any of the terms,
covenants or conditions of this Lease, either at the time Tenant sends Tenant’s ROFO Election Notice or upon executing the amendment, and has received written notice from Landlord to such effect, then Landlord shall have, in addition to all of
Landlord’s other rights and remedies provided in this Lease, the right to terminate the right of first offer contained herein upon notice to Tenant. 

17.3 Memorandum of Lease.  

(a) Concurrently with the execution and delivery of this Lease, the parties shall execute a short form memorandum in substantially the form
attached hereto as Exhibit K-1 (the “Memorandum of Lease”), and thereafter within thirty (30) days Landlord shall at its sole cost and expense cause such Memorandum of Lease to be recorded in the Official Records of
Santa Clara County, California. Tenant agrees that at the request of any lender or ground lessor, the subordination documents executed and delivered by Tenant pursuant to Paragraph 13.3 above shall include the subordination of such Memorandum of
Lease to the applicable deed of trust or ground lease. 
 (b) Within ten (10) business days after Landlord’s written request,
which request Landlord may make at any time during the last thirty (30) days of the Lease Term (as extended, if applicable), Tenant shall execute, have acknowledged, and deliver to Landlord a Termination of Memorandum of Lease in the form of
Exhibit K-2 attached hereto, whereupon Landlord shall be authorized to cause the same to be recorded in the Official Records of Santa Clara County, California, immediately upon or at any time after the expiration or earlier termination of
this Lease. Tenant’s obligation to execute and deliver such Termination of Memorandum of shall survive the expiration or earlier termination of this Lease. 

(c) From time to time within ten (10) business days after Landlord’s written request, which request Landlord may make during the
thirty (30) day period preceding any of Tenant’s rights set forth in this Article 17 lapsing or otherwise expiring, terminating, or becoming ineffective, or at any time after any of such rights have lapsed, terminated, or become
ineffective, Tenant or its successors or assigns claiming rights in this Article 17 shall promptly execute, have acknowledged, and deliver to the Landlord, a Termination of Certain Rights under Lease in the form of Exhibit K-3 attached
hereto, modified to specify those rights lapsing, terminating, or otherwise becoming ineffective, whereupon Landlord shall be authorized to cause the same to be recorded in the Official Records of Santa Clara County, California. Tenant’s
obligation to execute and deliver such Termination of Certain Rights under Lease shall survive the expiration or earlier termination of this Lease. 

[REMAINDER OF PAGE INTENTIONALLY LEFT BLANK] 

  
 50 

 Building C 
  

IN WITNESS WHEREOF, Landlord and Tenant have executed this Lease as of the respective dates below set forth with the intent to be legally bound
thereby as of the Effective Date of this Lease first above set forth. 
  

			
			TENANT:
			ARUBA NETWORKS, INC., a Delaware corporation
		
	Dated: April 14, 2015		By: /s/ Ava
Hahn                                         
                   
			Printed Name: Ava Hahn
			Title: General Counsel
		
	Dated: April 14, 2015		By: /s/ Henry D.
Bullock                                        
        
			Printed Name: Henry D. Bullock
			Title: President
		
			LANDLORD:

  

					
			    SANTA CLARA CAMPUS PROPERTY OWNER
I LLC,
    a Delaware limited liability company

			
			    By:
		 Santa Clara Campus Partners LLC,
 a Delaware
limited liability company,
 its Sole Member

							
				
					     By:
		 Menlo Equities Development Company IX LLC,
 a
California limited liability company,
 its Manager

											
						
									     By:
		 Menlo Equities V LLC,
 a California limited
liability company,
 its Manager

													
							
											 By:
		 Menlo Legacy Holdings L.P.,
 a California
limited partnership,
 its Managing Member

  

																					
	Dated: April 14, 2015																				By: /s/ Henry D. Bullock      
																					Henry D. Bullock, President

  
 51 

 Building C 
  

SCHEDULE 2.1 
 EXISTING
TITLE ENCUMBRANCES 
  

	1.	General and special taxes and assessments for the fiscal year 2014-2015. 

  

			
	 First Installment:
		$71,816.69, OPEN
	 Penalty:
		$0.00
	 Second Installment:
		$71,816.69, OPEN
	 Penalty:
		$0.00
	 Tax Rate Area:
		07-014
	 A. P. No.:
		216-31-082

 (Affects Parcel D) 
  

	2.	General and special taxes and assessments for the fiscal year 2014-2015. 

  

			
	 First Installment:
		$63,835.47, OPEN
	 Penalty:
		$0.00
	 Second Installment:
		$63,835.47, OPEN
	 Penalty:
		$0.00
	 Tax Rate Area:
		07-014
	 A. P. No.:
		216-31-083

 (Affects Parcel E) 
  

	2A.	General and special taxes and assessments for the fiscal year 2014-2015. 

  

			
	 First Installment:
		$74,403.03, OPEN

 [REMAINDER OF PAGE INTENTIONALLY LEFT BLANK] 

  
 1 

 Building C 
  

			
	 Penalty:
		$0.00
	 Second Installment:
		$74,403.03, OPEN
	 Penalty:
		$0.00
	 Tax Rate Area:
		07-014
	 A. P. No.:
		216-31-084

 (Affects Parcel A) 
  

	2B.	General and special taxes and assessments for the fiscal year 2014-2015. 

  

			
	 First Installment:
		$70,130.88, OPEN
	 Penalty:
		$0.00
	 Second Installment:
		$70,130.88, OPEN
	 Penalty:
		$0.00
	 Tax Rate Area:
		07-014
	 A. P. No.:
		216-31-085

 (Affects Parcel B) 
  

	2C.	General and special taxes and assessments for the fiscal year 2014-2015. 

  

			
	 First Installment:
		$76,313.19, OPEN
	 Penalty:
		$0.00
	 Second Installment:
		$76,313.19, OPEN
	 Penalty:
		$0.00
	 Tax Rate Area:
		07-014
	 A. P. No.:
		216-31-086

 (Affects Parcel C) 
  

	3.	The lien of supplemental taxes, if any, assessed pursuant to Chapter 3.5 commencing with Section 75 of the California Revenue and Taxation Code. 

 

	4.	Matters in a document entitled “Declaration of Covenants, Conditions, and Restrictions for Oakmead Village”, recorded December 28, 1973 in Book 0704, Page 601, Official Records, including but not limited
to covenants, conditions, restrictions, easements, assessments, liens and charges. 

 Amended Number One was recorded
November 26, 1974 in Book B187, Page 387, Official Records. 
 Notice of Addition of Real Property was recorded December 30, 1974
in Book B227, Page 134, Official Records. 
 Amendment Number Two was recorded March 26, 1975 in Book B334, Page 85, Official Records.

 Further Notices of Addition of Real Property were recorded December 8, 1976 in Book C462, Page 325; June 30, 1977 in Book
C959, Page 583; and June 30, 1977 in Book C959, Page 598, all Official Records. 
 Assignment of Grantor’s (Declarant’s)
Rights by Sequoia Pacific Realco, a general partnership, to 
 Campeau Corporation, was recorded April 4, 1978 in Book D570, Page 591,
Official Records. 
 Third Amendment was recorded October 07, 1987 in Book K317, Page 1365, Official Records. 

Assignment of Grantor’s Rights by Campeau Corporation, to Kimball Small Properties, Inc., was recorded June 11, 1993 in Book M826,
Page 1687, Official Records. 
  

	5.	An easement for any and all city utilities, access and incidental purposes, recorded June 28, 1977 in Book C951, Page 196 of Official Records. 

 

			
	 In Favor of:
		City of Santa Clara, a municipal corporation
	 Affects:
		As described therein

  

	6.	The terms and provisions contained in the document entitled “Covenant Running with Land and Lien” recorded April 23, 1980 in Book F289, Page 290 of Official Records. 

  
 2 

 Building C 
  

 

	7.	The terms and provisions contained in the document entitled “Covenant and Environmental Restriction on Property and Termination of Previous Covenant and Restriction” recorded February 28, 2012 as
Instrument No. 21551692 of Official Records. 

 Any claim asserted by reason of the facts disclosed or alluded to in the
document entitled “Covenant and Environmental Restriction on Property and Termination of Previous Covenant and Restriction”, recorded February 28, 2012, as Instrument No. 21551692, Official Records. 

 

	8.	A deed of trust to secure an original indebtedness of $99,600,000 recorded July 12, 2012 as Document No. 21745844 of Official Records. 

 

			
	Dated:		July 12, 2012
	Trustor:		Santa Clara Campus Property Owner I LLC, a Delaware limited liability company
	Trustee:		American Securities Company, a California corporation
	Beneficiary:		Wells Fargo Bank, N.A.

 The above deed of trust states that it is a construction deed of trust. 

A document recorded October 17, 2012 as Document No. 21904821 of Official Records provides that the deed of trust or the obligation
secured thereby has been modified. 
  

	9.	This item has been intentionally deleted. 

  

	10.	A financing statement recorded July 12, 2012 as Document No. 21745845 of Official Records. 

  

			
	Debtor:		Santa Clara Campus Property Owner I LLC
	Secured party:		Wells Fargo Bank, N.A.

  

	11.	An easement shown or dedicated on the map of Parcel Map recorded October 17, 2012 on file in book 856, page 23 through 26, of Parcel Maps. For: waterline, underground electrical, sidewalk, bus stop, driveway
access, recreation, traffic signal and incidental purposes. 

  

	12.	The terms, provisions and easement(s) contained in the document entitled “Declaration of Reciprocal Easements (Underground Utilities)” recorded October 17, 2012 as Document No. 21904819 of Official
Records. 

  

	13.	The terms, provisions and easement(s) contained in the document entitled “Declaration of Reciprocal Easements(Access)” recorded October 17, 2012 as Document No. 21904820 of Official Records.

  

	14.	Water rights, claims or title to water, whether or not shown by the public records. 

  

	15.	This item has been Intentionally deleted. 

  

	16.	Rights of parties in possession. 

  

	17.	An easement for any and all city utilities, access and incidental purposes, recorded December 18, 1974 in Book B213, Page 325 of Official Records. 

 

			
	In Favor of:		City of Santa Clara, a municipal corporation
	Affects:		As described therein

  

	18.	An easement for sidewalk and incidental purposes, recorded December 18, 1974 in Book B213, Page 348 of Official Records. 

  

			
	In Favor of:		City of Santa Clara, a municipal corporation
	Affects:		As described therein

  

	19.	An easement for landscape improvement and maintenance and incidental purposes, recorded March 13, 1975 as Document No. 4964044, Book B317, Page 80 of Official Records. 

 

			
	In Favor of:		City of Santa Clara, a municipal corporation
	Affects:		as described therein

  
 3 

 Building C 
  

 

	20.	An easement for any and all city utilities, access and incidental purposes, recorded April 23, 1975 in Book B374, Page 393 of Official Records. 

 

			
	In Favor of:		City of Santa Clara, a municipal corporation
	Affects:		As described therein

  

	21.	An easement for sidewalk and incidental purposes, recorded May 28, 1975 in Book B431, Page 623 of Official Records. 

  

			
	In Favor of:		City of Santa Clara, a municipal corporation
	Affects:		As described therein

  

	22.	An easement for pipeline for the transmission of nitrogen gas and incidental purposes, recorded April 29, 1976 in Book B998, Page 379 of Official Records. 

 

			
	In Favor of:		Air Products and Chemicals, Inc., a Delaware corporation
	Affects:		As described therein

 Document(s) declaring modifications thereof recorded November 16, 1976 in Book C414, Page 469 of Official
Records. 
 Document(s) declaring modifications thereof recorded January 15, 1980 in Book F83, Page 403 of Official Records. 

The interest of the Grantee therein has been assigned of record to Air Products Manufacturing Corporation, a Delaware corporation, by
instruments recorded October 24, 1983 in Book I008, Page 207, and February 7, 1984 in Book I291, Page 296 and April 3, 1984 in Book I429, Page 384, all of Official Records. 

 

	23.	An easement for any and all city utilities, access and incidental purposes, recorded June 28, 1977 in Book C951, Page 226 of Official Records. 

 

			
	In Favor of:		City of Santa Clara, a municipal corporation
	Affects:		As described therein

  

	24.	An easement for private underground storm drain and incidental purposes, recorded October 6, 1993 as Book N051, Page 1514 of Official Records. 

 

			
	In Favor of:		Garrett Drive, Inc., a Massachusetts Corporation
	Affects:		as described therein

  

	25.	The terms and provisions contained in the document entitled “stormwater treatment measures inspection and maintenance agreement” recorded May 10, 2013 as Document No. 22214357 of Official Records.

  

	26.	Any statutory lien for labor or materials arising by reason of a work of improvement, as disclosed by a notice of completion recorded November 26, 2013 as Document No. 22457850 of Official Records, which
reflects a completion date of November 19, 2013. 

  

	27.	An easement for underground electrical and incidental purposes, recorded November 20, 2014 as Document No. 22773897 of Official Records. 

 

			
	In Favor of:		City of Santa Clara, California, a chartered municipal corporation
	Affects:		as described therein

  
 4 

 Building C 
  

SCHEDULE 2.2(a) 

APPROVED PARKING AREA 
  

 

  
 1 

 Building C 
  

EXHIBIT A 
 SITE PLAN

  
 

 

  
 Exhibit A 

 Building C 
  

 
 EXCLUSIVE USE AREA = AREA DENOTED
BY RED LINES ABOVE 

  
 Exhibit B 

 Building C 
  

EXHIBIT B 
 FLOOR PLAN

  
 

 

  
 Exhibit B 

 Building C 
  

EXHIBIT C 
 PREMISES
MEASUREMENT METHOD 
  

											
	 	  	1st Floor	  	2nd Floor	  	3rd Floor	  	4th Floor	  	Total
	Building C Common Area Square Footage	  	 
	 Lobby
	  	2,288	  	736	  	n/a	  	n/a	  	3,024
	 Elevator Equipment Rm
	  	228	  	n/a	  	n/a	  	n/a	  	228
	 Women’s Shower
	  	175	  	n/a	  	n/a	  	n/a	  	175
	 Men’s Shower
	  	175	  	n/a	  	n/a	  	n/a	  	175
	 Stair #1 Corridor
	  	220	  	n/a	  	n/a	  	n/a	  	220
	 Stair #2 Corridor
	  	352	  	n/a	  	n/a	  	n/a	  	352
	 Shared Main Electrical
	  	78	  	n/a	  	n/a	  	n/a	  	78
	 Fire Riser
	  	33	  	n/a	  	n/a	  	n/a	  	33
	 MPOE
	  	85	  	n/a	  	n/a	  	n/a	  	85
	 Building C Common Area SF
	  	3,634	  	736	  	0	  	0	  	4,370
						
	 Fitness
	  	n/a	  	n/a	  	n/a	  	n/a	  	0
	 Cafeteria
	  	n/a	  	n/a	  	n/a	  	n/a	  	0
	 Phase I Campus Common Area SF
	  	0	  	0	  	0	  	0	  	0
	 Total Common Area SF
	  	3,634	  	736	  	0	  	0	  	4,370
						
	 	  	1st Floor	  	2nd Floor	  	3rd Floor	  	4th Floor	  	Total
	Usable Square Footage
	 Tenant
	  	30,812	  	34,257	  	35,908	  	35,908	  	136,885
	 Elevator
	  	199	  	199	  	199	  	199	  	796
	 Restroom & Janitor
	  	1,037	  	984	  	984	  	984	  	3,989
	 Stair #1
	  	475	  	473	  	473	  	473	  	1,894
	 Stair #2
	  	475	  	475	  	475	  	475	  	1,900
	 Tenant Electrical
	  	199	  	199	  	199	  	199	  	796
	 IDF
	  	169	  	199	  	199	  	199	  	766
	 Mechanical Shaft #1
	  	n/a	  	271	  	271	  	271	  	813
	 Mechanical Shaft #2
	  	n/a	  	364	  	364	  	364	  	1,092
	 Mechanical Shaft
	  	n/a	  	40	  	40	  	40	  	120
	 Building C Usable SF
	  	33,366	  	37,461	  	39,112	  	39,112	  	149,051
						
	 Building C Single Tenant Gross SF
	  	37,000	  	38,197	  	39,112	  	39,112	  	153,421
						
	 	  	1st Floor	  	2nd Floor	  	3rd Floor	  	4th Floor	  	Total
	 Building C Usable SF
	  	33,366	  	37,461	  	39,112	  	39,112	  	149,051
	 Building C Common Area SF Allocation
	  	978	  	1,098	  	1,147	  	1,147	  	4,370
	 Building C Cafeteria & Fitness SF Allocation
	  	776	  	872	  	910	  	910	  	3,468
	 Building C Rentable SF based upon Single Tenant Gross SF
	  	35,121	  	39,431	  	41,169	  	41,169	  	156,889

  

																									
	3333 Scott Boulevard	 
	 Address
	  	Single Tenant
Gross Bld SF	 	  	Gross Bld SF (excl.
Campus Common
Areas)	 	  	Allocable Phase I & II
Campus Cafeteria SF
(Bldgs. A-C)	 	 	Allocable Phase I & II
Campus Fitness Center
SF (Bldgs. A-D)	 	 	Total Allocations	 	 	Total Bldg.
Rentable
SF	 
	 Bldg A - 1st Floor
	  	 	37,088	  	  				  				 				 				 			
	 Bldg A - 2nd Floor
	  	 	37,811	  	  				  				 				 				 			
	 Bldg A - 3rd Floor
	  	 	38,736	  	  				  				 				 				 			
	 Bldg A - 4th Floor
	  	 	38,736	  	  				  				 				 				 			
							
	 Building A Total
	  	 	152,371	  	  	 	141,305	  	  	 	(5,766	) 	 	 	(2,106	) 	 	 	(7,872	) 	 	 	144,499	  
	 Bldg B - 1st Floor
	  	 	37,531	  	  				  				 				 				 			
	 Bldg B - 2nd Floor
	  	 	38,183	  	  				  				 				 				 			
	 Bldg B - 3rd Floor
	  	 	39,109	  	  				  				 				 				 			
	 Bldg B - 4th Floor
	  	 	39,109	  	  				  				 				 				 			
							
	 Building B Total
	  	 	153,932	  	  	 	153,932	  	  	 	2,888	  	 	 	592	  	 	 	3,480	  	 	 	157,412	  
	 Bldg C - 1st Floor
	  	 	37,000	  	  				  				 				 				 			
	 Bldg C - 2nd Floor
	  	 	38,197	  	  				  				 				 				 			
	 Bldg C - 3rd Floor
	  	 	39,112	  	  				  				 				 				 			
	 Bldg C - 4th Floor
	  	 	39,112	  	  				  				 				 				 			
							
	 Building C Total
	  	 	153,421	  	  	 	153,421	  	  	 	2,878	  	 	 	590	  	 	 	3,468	  	 	 	156,889	  
							
	 Building D Total
	  	 	244,880	  	  	 	244,880	  	  	 	0	  	 	 	924	  	 	 	924	  	 	 	245,804	  
							
	 TOTAL PHASE I
	  	 	704,604	  	  	 	693,538	  	  	 	0	  	 	 	0	  	 	 	0	  	 	 	704,604	  

  
 Exhibit C 

 Building C 
  

EXHIBIT D 
 WORK LETTER

 THIS TENANT WORK LETTER (“Work Letter”) sets forth the agreement of Landlord and Tenant with respect to the
improvements to be constructed in the Leased Premises, as defined in the Lease to which this Work Letter is attached as an exhibit. In the event of any inconsistency between the terms of this Work Letter and the terms of the Lease, the terms of the
Lease shall control. All defined terms used herein shall have the meanings set forth in the Lease, unless otherwise defined in this Work Letter. 

1. Landlord’s Work. 

(a) Landlord’s Completed Work. Landlord has constructed the base building warm shell of the Building, which is a four-story, steel
frame building containing the components listed on Exhibit A-1 attached hereto (the “Warm Shell Components”), in accordance with the plans for the Building which were approved by the City of Santa Clara (the “Final
Base Building Plans”), and the Site Plan (which remains subject to approval, and changes if any are required, by the City of Santa Clara), and in compliance with all Laws applicable thereto on the date the Building was substantially
completed by Landlord (“Landlord’s Completed Work”). Landlord has provided Tenant’s architect with a CAD file of the Final Base Building Plans, and Landlord represents to Tenant that the base building warm shell of the
Building has been constructed in accordance with such Final Base Building Plans. 
 (b) Landlord’s Additional Work. Landlord
will (a) pursuant to Paragraph 5.2(a) of the Lease, upgrade the base building transformer to provide 4,000 amps, subject to the approval of Silicon Valley Power Company, and (b) construct (i) the Building’s ground floor lobby,
with finishes similar to the lobby finishes in the buildings located at 3355 and 3325 Scott Boulevard, and (ii) exit corridors from stairwells as shown shaded on Exhibit A-2 attached hereto (“Landlord’s Additional
Work”). Landlord shall substantially complete the Landlord’s Additional Work by July 1, 2016, subject to Force Majeure and any periods of delay caused by Tenant Delay. 

2. Tenant Improvements. Tenant shall construct, furnish or install such improvements, equipment or fixtures as are necessary for
Tenant’s use and occupancy of the Leased Premises (collectively, the “Tenant Improvements”). Tenant shall complete construction of the Tenant Improvements for the entirety of the Leased Premises. Tenant shall also be
responsible for the cost of any alterations to the Building required as a result of the Tenant Improvements unless such alterations are required due to Landlord’s failure to build the Warm Shell Components in accordance with the Final Base
Building Plans or applicable Laws. Tenant has engaged and Landlord has approved Alex Ingram to manage the design and construction of the Tenant Improvements (“Tenant Improvement Project Manager”). Tenant shall cause all drawings and
specifications for the Tenant Improvements to be prepared by an architect selected by Tenant and reasonably approved by Landlord (“Tenant Improvement Architect”) and to be constructed by a general contractor licensed in California,
selected by Tenant, and reasonably approved by Landlord (“Tenant Improvement Contractor”). Tenant has engaged and Landlord has approved Devcon Construction Inc. to be the Tenant Improvement Contractor. Landlord’s prior written
consent, which shall not be unreasonably withheld, shall be required if Tenant desires to change its Tenant Improvement Architect, Tenant Improvement Contractor or Tenant Improvement Project Manager. Tenant shall furnish to Landlord a copy of the
executed contracts between Tenant and Tenant Improvement Architect, and Tenant and Tenant Improvement Contractor, covering all of Tenant’s obligations under this Work Letter; Landlord agrees to keep treat such contracts as confidential
information pursuant to and in accordance with Paragraph 13.7 of the Lease. 
 The Tenant Improvements shall be in conformity with drawings
and specifications submitted to and approved by Landlord, which approval shall not be unreasonably withheld or delayed, and shall be performed in accordance with the following provisions: 

Tenant Improvement Space Plans: Tenant shall prepare and submit to Landlord for its approval Tenant Improvement space plans (the
“Tenant Improvement Space Plans”). Within five (5) business days after receipt of Tenant’s drawings Landlord shall return one set of prints thereof with Landlord’s approval and/or suggested modifications noted
thereon. If Landlord fails to respond within five (5) business days, then Tenant may send a notice to Landlord, which notice must contain the following inscription, in 14 point font and bold faced lettering: “SECOND NOTICE DELIVERED
PURSUANT TO WORK LETTER—FAILURE TO TIMELY RESPOND WITHIN FIVE (5) BUSINESS DAYS SHALL RESULT IN DEEMED APPROVAL.” If Tenant sends such a notice, and Landlord fails to respond within five (5) business days after its receipt of
same, the proposed drawings shall be deemed approved. If Landlord has approved Tenant’s drawings subject to modifications, such modifications shall be deemed to be acceptable to and approved by Tenant unless Tenant shall prepare and resubmit
revised drawings for further consideration by Landlord. If Landlord has suggested modifications 

  
 Exhibit D 

 Building C 
  

without approving Tenant’s drawings Tenant shall prepare and resubmit revised drawings. All revised drawings shall be submitted, with
changes highlighted, to Landlord, and Landlord shall approve or disapprove such revised drawings within five (5) business days following receipt of the same. Landlord shall be provided with a copy of Tenant’s preliminary floor plan and
associated CAD files as a condition to receiving reimbursement. Notwithstanding anything herein to the contrary, Landlord may only object to such Tenant Improvement Space Plans if they present a Design Problem. As used in this Work Letter and in the
Lease, the term “Design Problem” means that the proposed alteration, Tenant Improvements, or other work would cause an adverse effect on the structural aspects of the Building or Building Systems, trigger any obligation of Landlord
to make the Building comply with Laws (unless Tenant pays for the cost of such compliance), vitiate or otherwise reduce any warranty for Landlord’s benefit with respect to the Building or Project, increase the cost of Landlord’s
maintenance or repair costs with respect to the Building or Project unless such costs are paid by Tenant as billed by Landlord, conflict with applicable codes or other Laws, affect the exterior appearance of the Building, or increase the cost of
construction, or delay completion, of the Landlord’s Additional Work. 
 Tenant Improvement Design Development Plans: Tenant
shall prepare and submit to Landlord for its approval Tenant Improvement design development plans (“Tenant Improvement Design Development Plans”). Within five (5) business days after receipt of Tenant’s drawings Landlord
shall return one set of prints thereof with Landlord’s approval and/or suggested modifications noted thereon. If Landlord fails to respond within five (5) business days, then Tenant may send a notice to Landlord, which notice must contain
the following inscription, in 14 point font and bold faced lettering: “SECOND NOTICE DELIVERED PURSUANT TO WORK LETTER—FAILURE TO TIMELY RESPOND WITHIN FIVE (5) BUSINESS DAYS SHALL RESULT IN DEEMED APPROVAL.” If Tenant
sends such a notice, and Landlord fails to respond within five (5) business days after its receipt of same, the proposed drawings shall be deemed approved. If Landlord has approved Tenant’s drawings subject to modifications, such
modifications shall be deemed to be acceptable to and approved by Tenant unless Tenant shall prepare and resubmit revised drawings for further consideration by Landlord. If Landlord has suggested modifications without approving Tenant’s
drawings Tenant shall prepare and resubmit revised drawings for consideration by Landlord. All revised drawings shall be submitted, with changes highlighted, to Landlord following Landlord’s return to Tenant of the drawings originally
submitted, and Landlord shall approve or disapprove such revised drawings within five (5) business days following receipt of the same. Notwithstanding anything herein to the contrary, Landlord may only object to such Tenant Improvement Design
Development Plans if they present a Design Problem. 
 Tenant Improvement Working Drawings: Tenant shall prepare and submit to
Landlord for its approval Tenant Improvement working drawings (“Tenant Improvement Working Drawings”) including mechanical, electrical, and plumbing plans (“MEP”). Within five (5) business days after receipt of
Tenant’s drawings Landlord shall return one set of prints thereof with Landlord’s approval and/or suggested modifications noted thereon. If Landlord fails to respond within five (5) business days, then then Tenant may send a notice to
Landlord, which notice must contain the following inscription, in 14 point font and bold faced lettering: “SECOND NOTICE DELIVERED PURSUANT TO WORK LETTER—FAILURE TO TIMELY RESPOND WITHIN FIVE (5) BUSINESS DAYS SHALL RESULT IN
DEEMED APPROVAL.” If Tenant sends such a notice, and Landlord fails to respond within five (5) business days after its receipt of same, the proposed drawings shall be deemed approved. If Landlord has approved Tenant’s drawings
subject to modifications, such modifications shall be deemed to be acceptable to and approved by Tenant unless Tenant shall prepare and resubmit revised drawings for further consideration by Landlord. If Landlord has suggested modifications without
approving Tenant’s drawings Tenant shall prepare and resubmit revised drawings for consideration by Landlord. All revised drawings shall be submitted, with changes highlighted, to Landlord following Landlord’s return to Tenant of the
drawings originally submitted, and Landlord shall approve or disapprove such revised drawings within five (5) business days following receipt of the same. Notwithstanding anything herein to the contrary, Landlord may only object to such Tenant
Improvement Working Drawings if they present a Design Problem. 
 Final Tenant Improvement Plans: Tenant shall submit the approved
Tenant Improvement Working Drawings to the Santa Clara Building Department for a Tenant Improvement building permit prior to the commencement of such work. The Tenant Improvement Working Drawings as modified by the City of Santa Clara are defined
herein as the “Final Tenant Improvement Plans.” Prior to commencing construction, Tenant shall deliver to Landlord a copy of the City of Santa Clara building permit for the Final Tenant Improvement Plans. 

Any material changes to the Final Tenant Improvement Plans shall be subject to Landlord’s prior written approval, which shall not be
unreasonably withheld. As used herein, the term “Material Changes” shall mean: a change to the Final Tenant Improvement Plans that exceeds Forty Thousand Dollars ($40,000) in cost or could reasonably be expected to cause a
Design Problem. 

  
 Exhibit D 

 Building C 
  

Subject to Landlord’s review and approval of all applicable plans and specifications, Tenant shall have the right to: (a) install
communication conduit between the Building and Building D; (b) specify, purchase, and utilize its own cosmetic and/or decorative materials including, but not limited to, floor coverings, paint, and wall coverings; (c) make floor cores
consistent with normal office uses that do not interfere with the structural integrity of any floor; (d) install Tenant’s own security card access systems to the Leased Premises; and (e) secure the Leased Premises during and after
business hours. 
 Tenant acknowledges that it will engage the Tenant Improvement Architect, the Tenant Improvement Project Manager, and the
Tenant Improvement Contractor, and shall be solely responsible for the actions and omissions of its architects, engineers, contractors, and project/construction managers and for any loss, liability, claim, cost, damage or expense suffered by
Landlord or any other entity or person as a result of the acts or omissions of its architect, engineers or project/construction managers. Landlord’s approval of any of Tenant’s architects, engineers or project/construction managers and of
any documents prepared by any of them shall not be for the benefit of Tenant or any third party, and Landlord shall have no duty to Tenant or to any third parties for the actions or omissions of Tenant’s architects, engineers or
project/construction managers. Tenant shall indemnify and hold harmless Landlord from and against any and all losses, costs, damages, claims and liabilities arising from the actions or omissions of Tenant’s architects, engineers and
project/construction managers. 
 The Tenant Improvements shall be constructed by Tenant Improvement Contractor in accordance with the Final
Tenant Improvement Plans, in compliance with all of the terms and conditions of this Work Letter and the Lease, and with all applicable Laws and Restrictions. Tenant or the Tenant Improvement Contractor shall obtain a builder’s risk policy of
insurance in an amount and form and issued by a carrier reasonably satisfactory to Landlord, and its subcontractors shall carry worker’s compensation insurance for their employees as required by law. The builder’s risk policy of insurance
shall name Landlord as an additional insured and shall not be cancelable without at least thirty (30) days’ prior written notice to Landlord. 

Tenant shall notify Landlord of its intention to commence construction five (5) days prior to commencement and shall again notify
Landlord of actual commencement within one (1) business day thereafter. Landlord shall have the right to post in a conspicuous location on the Building or the Leased Premises, as well as record with the County of Santa Clara, a Notice of
Nonresponsibility. Tenant shall provide Landlord with a copy of the City of Santa Clara building permit allowing for the construction of the Final Tenant Improvement Plans prior to commencement of construction of the Tenant Improvements. 

Tenant shall, and shall cause Tenant’s Project Manager to, use commercially reasonable efforts to cause construction of the Final Tenant
Improvement Plans to be performed in as efficient a manner as is commercially reasonable. All work to be performed inside or outside of the Building shall be coordinated with Landlord. Tenant and the Tenant Improvement Contractor shall conduct their
work and employ labor for the Tenant Improvements in such manner as to maintain harmonious labor relations. 
 Tenant, at Tenant’s sole
cost and expense, shall clear debris resulting from the Tenant Improvement construction as necessary so as not to interfere with the construction of the Landlord’s Additional Work. No trash, or other debris, or other waste may be deposited at
any time outside the Building except in containers reasonably approved by Landlord. If so, Landlord may, after written notice to Tenant, remove it at Tenant’s expense, which expense shall equal the cost of removal plus ten percent (10%) of such
costs as a management fee. Storage of Tenant Improvement construction materials, tools and equipment shall be coordinated with Landlord’s contractor. Tenant shall reimburse Landlord on demand for the cost of repairing any damage to the Building
caused by Tenant Improvement Contractor and its subcontractors during the construction of the Tenant Improvements. Upon completion of the Tenant Improvements, Tenant shall cause the Building and the Common Areas to be clean and free from
construction debris resulting from Tenant’s Tenant Improvement construction. 
 Tenant shall submit to Landlord upon completion of the
Tenant Improvements a Certificate of Substantial Completion, AIA Document G704, by its Tenant Improvement Architect for the Final Tenant Improvement Plans, a copy of all final inspection cards for the Tenant Improvements signed by the appropriate
City of Santa Clara inspector and the Temporary Certificate of Occupancy from the City of Santa Clara. 
 Tenant shall submit to Landlord
two CDs containing copies of all Tenant Improvement as-built plans and specifications, or final field drawings covering all of the work in the Final Tenant Improvement Plans. 

Any minor work required for Tenant’s occupancy of the Leased Premises but not included in the Final Tenant Improvement Plans such as the
procurement and installation of furniture, fixtures, equipment, interior artwork and signage, shall not require Landlord approval but shall be installed in a good and workmanlike manner by Tenant. 

  
 Exhibit D 

 Building C 
  

3. Project Costs. The costs and expenses of the development and construction of the Landlord’s Additional Work and the Tenant
Improvements (“Project Costs”) shall be paid in accordance with this Paragraph 3. 
 (a) Landlord’s Additional
Work. The costs and expenses of the development and construction of the Landlord’s Additional Work shall be paid by Landlord. 

(b) Tenant Improvements. Unless specified otherwise herein, Tenant shall bear and pay the cost of the Tenant Improvements (which cost
shall include, without limitation, the costs of construction as provided for in the Tenant Improvement Contractor’s contract, the cost of permits, and all architectural, design, space planning, and engineering services obtained by Tenant in
connection with Tenant Improvements, office improvements, wiring and cabling costs, and cubicle costs; provided that, so long as Tenant is not in monetary or material non-monetary default under the Lease or this Work Letter, Landlord shall
contribute a maximum of $65 per rentable square foot, for an aggregate maximum of $2,282,865 (the “Tenant Improvement Allowance”), but in no event more than $65 per square foot of the applicable space under construction, which shall
be utilized only for building improvements to the Building, and for any related costs, including but not limited to design, engineering, construction, furniture and equipment appurtenant to the Leased Premises, cabling, project management fees,
moving expenses, and signage, and shall be available to Tenant only until the date which is twelve (12) months after the Lease Commencement Date (the “TI Allowance Deadline”), after which Landlord shall have no further
obligation to provide any portion of the Tenant Improvement Allowance. Landlord shall have no obligation to make disbursements of the Tenant Improvement Allowance at any time that Landlord has delivered written notice of a monetary or material
non-monetary default under the Lease or this Work Letter by Tenant until such default has been cured. Subject to such TI Allowance Deadline, and based upon applications for payment prepared, certified and submitted by Tenant as described below,
Landlord shall make progress payments from the Tenant Improvement Allowance to Tenant in accordance with the provisions of this Paragraph 3 (but in no event more than $65 per square foot for the applicable space under construction), as follows: 

(i) Not later than the 25th day of each month Tenant shall submit applications for payment to Landlord in a form reasonably acceptable to
Landlord, including Tenant Improvement Contractor’s Application and Certification for Payment AIA G702 certified by Tenant Improvement Architect, certified as correct by an officer of Tenant and by Tenant’s architect, for payment of that
portion of the cost of the Tenant Improvements allocable to labor, materials and equipment incorporated in the Building or Common Areas during the period from the first day of the same month projected through the last day of the month. Each
application for payment shall set forth such information and shall be accompanied by such supporting documentation as shall be reasonably requested by Landlord, including the following: 

(A) Invoices and canceled checks. 

(B) Fully executed conditional lien releases in the form prescribed by law from the Tenant Improvement Contractor and all subcontractors and
suppliers furnishing labor or materials during such period and fully executed unconditional lien releases from all such entities covering the prior payment period. 

(C) Tenant Improvement Contractor’s worksheets showing percentages of completion. 

(D) Tenant Improvement Contractor’s certification as follows: 

“There are no known mechanics’ or materialmen’s liens outstanding at the date of this application for payment, all due and
payable bills with respect to the Building have been paid to date or shall be paid from the proceeds of this application for payment, and there is no known basis for the filing of any mechanics’ or materialmen’s liens against the Building
or the Property, and, to the best of our knowledge, waivers from all subcontractors are valid and constitute an effective waiver of lien under applicable law to the extent of payments that have been made or shall be made concurrently herewith.”

 (ii) On or before the 15th day following submission of the application for payment, so long as Tenant is not in default under the terms
of this Work Letter or the Leases, Landlord shall pay a share of such payment determined by multiplying the amount of such payment by a fraction, the numerator of which is the amount of the Tenant Improvement Allowance, and the denominator of which
is the sum of (i) estimated construction cost of all Tenant Improvement work and materials for the entire Leased Premises and Common Areas, and (ii) the estimated cost of all professional services, fees and

  
 Exhibit D 

 Building C 
  

permits in connection therewith. Tenant shall pay the balance of such payment, provided that at such time as Landlord has paid the entire Tenant Improvement Allowance on account of such Tenant
Improvement work, all billings shall be paid entirely by Tenant; provided, however, that Landlord shall have no obligation to make disbursements of the Tenant Improvement Allowance at any time that Landlord has delivered written notice of a monetary
or material non-monetary default under the Lease or this Work Letter by Tenant until such default has been cured. If upon completion of the Tenant Improvement Work and payment in full to the Tenant Improvement Contractor, the architect and engineer,
and payment in full of all fees and permits, the portion of the cost of the Tenant Improvement Work, architects’ and engineers’ fees, permits and fees theretofore paid by Landlord is less than the Tenant Improvement Allowance, Landlord
shall reimburse Tenant for costs expended by Tenant for Tenant Improvement work up to the amount by which the Tenant Improvement Allowance exceeds the portion of such cost theretofore paid by Landlord. Landlord shall have no obligation to advance
the Tenant Improvement Allowance to the extent it exceeds the total cost of the Tenant Improvement Work. In no event shall Landlord have any responsibility for the cost of the Tenant Improvement Work in excess of the Improvement Allowance. Landlord
shall have no obligation to make any payments to Tenant Improvement Contractor’s material suppliers or subcontractors or to determine whether amounts due them from Tenant Improvement Contractor in connection with the Tenant Improvement work
have, in fact, been paid. The foregoing shall not be read to prevent Tenant from curing the applicable default and then being entitled to the applicable disbursement once the default is cured if such cure is completed within the applicable cure
period, if any, expressly set forth in this Work Letter or the Lease. 
 (c) Additional Allowance for Tenant Work. Upon Tenant’s
written request made at least thirty (30) days prior to the Lease Commencement Date, so long as Tenant is not in monetary or material non-monetary default under the Lease or this Work Letter, but as an increase in the Base Monthly Rent payable
by Tenant, Landlord will provide an additional amount, to be added to the Tenant Improvement Allowance and disbursed as provided with respect thereto in subparagraph 3(b) above, of $15 per rentable square foot, for an aggregate maximum of $526,815
(the “Additional Tenant Improvement Allowance”), but in no event more than $15 per square foot of the applicable space under construction. The amount of the Additional Tenant Improvement Allowance shall accrue interest at the per
annum rate of six percent (6%), compounded monthly, from the date each portion thereof is contributed by Landlord, and the total amount thereof (including accrued interest) shall be fully amortized in equal monthly installments, commencing on the
later of (i) the Lease Commencement Date, and (ii) the first day of the first full calendar month following the first to occur of (A) the final disbursement by Landlord of the Additional Tenant Improvement Allowance, and (B) the
TI Allowance Deadline, and ending on the first day of the 132nd month of the Lease Term, utilizing a per annum rate of six percent (6%), compounded monthly, and the amount of each monthly
installment shall be added to and become a part of the Base Monthly Rent. 
 (d) Test Fit Allowance. Landlord and Tenant acknowledge
that Landlord has previously provided Tenant with a satisfactory test fit allowance to be used by Tenant in the development of the Tenant Improvement Space Plans. 

(e) Evidence of Completion of Improvement Work. Upon the completion of the Improvement Work, Tenant shall: 

(i) Submit to Landlord a detailed breakdown of Tenant’s final and total construction costs, together with receipted evidence showing
payment thereof, satisfactory to Landlord. 
 (ii) Submit to Landlord all Tenant Improvement building permits signed off by the City and any
certificate of occupancy received by Tenant for the Leased Premises. 
 (iii) Submit to Landlord, electronically in .pdf format or zip
drive, the as-built plans and specifications or final field drawings referred to above. 
 4. Tenant Delay. For the purposes of this
Work Letter and the Lease, “Tenant Delay” means any actual delay in the Landlord’s completion of the Landlord’s Additional Work resulting from either: (i) Tenant’s failure to fulfill its obligation with respect to
provide either documents or approvals within the time periods specified therefor herein, (ii) any matters specifically identified elsewhere in this Work Letter or in the Lease as Tenant delays, or (iii) an act or omission of Tenant or any
Tenant Parties which interferes with the progress of construction of the Building. In the event of any Tenant Delay the date upon which Substantial Completion of the Landlord’s Additional Work is deemed to have occurred shall be advanced by the
cumulative duration of such Tenant Delays, and the Delivery Date shall be deemed to have occurred in advance of the actual delivery date as a sole and direct result of the cumulative duration of such Tenant Delays. A Tenant Delay shall not be deemed
to have commenced until Landlord has provided written notice to Tenant that a Tenant Delay is occurring. 
 5. Unavoidable Tenant
Improvement Delays. As used in this Work Letter, the term “Unavoidable Tenant Improvement Delay” shall mean any delays Tenant experiences in constructing 

  
 Exhibit D 

 Building C 
  

the Tenant Improvements which actually and directly, without intervening cause, materially and adversely affect Tenant’s construction of the Tenant Improvements and prevent Tenant from
completing the Tenant Improvements by the Lease Commencement Date as a result of acts of God or nature, delays in obtaining permits, or government shut-down. 

6. Landlord Delays. A “Landlord Delay” means the length of any actual delay in the permitting, construction or completion of
the Tenant Improvements or equipment to be installed by Tenant which actually and directly delays Substantial Completion of the Tenant Improvements beyond the date set forth in Paragraph 2.4(c) of the Lease (as such date may be extended pursuant to
Paragraph 2.4(c) of the Lease), which (a) is not caused by Force Majeure, and (b) is caused by Landlord’s interference with Tenant’s Substantial Completion of the Tenant Improvements or placement of furniture, fixtures or
equipment in the Leased Premises caused by acts or omissions of Landlord or its agents or contractors. For the purposes of this Paragraph 6 only, the term “Substantial Completion” means that the Tenant Improvements have been
substantially completed pursuant to the details of the Final Tenant Improvement Plans but for punch list items which don’t materially and adversely affect Tenant’s use of the Leased Premises and a temporary certificate of occupancy for the
Leased Premises has been issued by the City of Santa Clara. 
 7. Assignment of Rights Against Architect, Contractor, etc. Tenant
hereby assigns to Landlord on a non-exclusive basis any and all rights Tenant may have against the Tenant Improvement Contractor, the Tenant Improvement Architect, the Tenant Improvement Project Manager, and any other of Tenant’s consultants,
subcontractors, agents, etc., relating to the Tenant Improvements, without in any way obligating Landlord to pursue or prosecute such rights. Landlord acknowledges and agrees that such assignment is for security purposes only, and is not an absolute
or current assignment of such rights. If Tenant defaults in Tenant’s obligations pursuant to this Lease and, as a result thereof, Landlord successfully exercises Landlord’s rights pursuant to the California Civil Code then such assignment
shall be an absolute assignment to Landlord of such rights, but until such time then Tenant shall be the sole owner of such rights and may enforce them or not as Tenant deems appropriate, in Tenant’s sole judgment. Tenant shall promptly cause
the Tenant Improvement Contractor, the Tenant Improvement Architect, the Tenant Improvement Project Manager, and any other of Tenant’s consultants, subcontractors, agents, etc. (once each such person has been engaged) to execute and deliver to
Landlord a consent in the form of Exhibit B hereto, consenting to the foregoing assignment. 
 8. Arbitration. All disputes
under this Work Letter shall be submitted to arbitration under the office of JAMS in San Francisco, California, and shall be conducted pursuant to its Streamlined Arbitration Rules and Procedures (and Landlord and Tenant hereby submit to arbitration
of such matter by JAMS and the determination of such arbitrator shall be final and binding upon both Landlord and Tenant). 

  
 Exhibit D 

 Building C 
  

EXHIBIT A-1 TO WORK LETTER 

3315 (Building C) Scott Boulevard, Santa Clara 

Landlord’s Warm Shell (Base Building & Core) 

GENERAL DESCRIPTION: Landlord’s shell and core shall comply with all codes and regulations, including fire, building, Title 24 and ADA. Building
Warm Shell has been awarded LEED Silver designation. 
  

	 	•	 	The building is a steel frame structure with glass and precast concrete window wall system with a curtain wall system at the entry. 

  

	 	•	 	Interior brace frames with exterior moment frames. 

  

	 	•	 	Glass/metal frame entry doors. 

  

	 	•	 	Roof Screen is incorporated in the overall architectural design and included in the warm shell. 

  

	 	•	 	15’6” floor-to-floor clearance on ground floor and 14’6” on upper floors to allow for an 11’+/- ceiling height on the ground floor and a 10’ +/- finished ceiling on the upper floors.

  

	 	•	 	Two exit stairs. 

  

	 	•	 	Finish of upper floor elevator lobbies are excluded; to be completed by Tenant as part of TIs. Main ground floor lobby is included. 

  

	 	•	 	Cafeteria and Fitness area provided on the ground floor of 3355 Scott Boulevard (Building A). 

 CONCRETE
FLOORS 
  

	 	•	 	Floor flatness/levelness is consistent with ASTM E1155/E 1155M. 

  

	 	•	 	The floors are designed for structural loading capability that can accommodate the placement of furnishings, fixtures and equipment that is consistent with the needs of a typical office tenant - live load of 100psf.
High density loads by Tenant are not anticipated. 

 EXTERIOR GLASS 

 

	 	•	 	Exterior glass is Title 24 compliant, insulated, free from scratches, nicks, cracks, marring and the intrusion of weather. 

ELEVATORS 
  

	 	•	 	Three 3,500 lb capacity Kone traction elevators that have a rated speed of 200 fpm are provided. Side opening doors with 9’-3” cab finished ceiling height. 

 

	 	•	 	Cab floors finished by Landlord to match the ground floor lobby. 

  

	 	•	 	All elevator cars, lobby call lanterns and call buttons are in compliance with all codes and regulations. 

  

	 	•	 	No service elevator is provided. 

  

	 	•	 	No elevator cars security card readers; part of TIs. 

 PERIMETER CONDITIONS AND BUILDING CORE 

 

	 	•	 	Lights, finished walls, ceiling and floor tile are provided in restrooms and exit corridors only; lights and unfinished walls in electrical rooms. Toilet exhaust at restrooms included. IT closets are part of TI
construction. 

  

	 	•	 	Exit stairwells with painted walls, finished ceilings, handrails, lights and noise reducing epoxy sealed floors stairs and landings. 

 

	 	•	 	Exposed window wall system. Completed window assembly with painted metal frames. 

  

	 	•	 	Exterior building envelop insulation as per Title 24, roof insulation and firesafing are included. No drywall is included except in the core areas. Core walls are framed, drywalled and fire taped finish.

  

	 	•	 	Code compliant premium grade finished doors, complete with frame, trim and hardware, installed at all stairwells, toilet rooms, service areas and all doors that open to the exterior. 

PERIMETER WINDOW COVERINGS 
  

	 	•	 	Landlord’s architect shall specify a horizontal mini-blind system for windows; to be mutually approved and installed by Tenant as part of TIs. 

TOILET ROOMS 
  

	 	•	 	Women’s and men’s toilet rooms are designed and constructed in compliance with current code requirements, laws and recommendations for size and quantity, including the Americans with Disabilities Act. Tenant
shall pay for any above code requirements. The design and finish shall include the following: 

  

	 	•	 	Water (hot and cold) shall be provided for all toilet rooms. 

  

	 	•	 	Lavatory counters shall have quality solid surface tops with recessed lavatories. 

  

	 	•	 	All faucets shall have auto-sensors. 

  

	 	•	 	Code required wet walls shall be finished with full height ceramic tile. 

  

	 	•	 	Includes floor drains. 

  

	 	•	 	The ceilings shall be painted with semi-gloss paint. 

  

	 	•	 	Toilet partitions shall be floor mounted; baked enamel or P-lam. 

  
 Exhibit D 

 Building C 
  

 

	 	•	 	Urinal partitions shall be wall mounted. 

  

	 	•	 	Low flow toilets and urinals shall be wall mounted in all restrooms. 

  

	 	•	 	Code compliant lighting only. 

  

	 	•	 	Showers in each ground floor men’s and women’s restroom. 

  

	 	•	 	All fixtures are porcelain and ADA compliant. 

  

	 	•	 	Accessories include: 

  

	 	•	 	Recessed seat cover dispenser 

  

	 	•	 	Recessed paper towel dispenser/waste receptacles 

  

	 	•	 	Recessed feminine napkin vendor 

  

	 	•	 	Recessed mounted roll toilet tissue dispensers 

  

	 	•	 	Handicap grab bar as required by code 

  

	 	•	 	Lavatory soap dispensers 

 WASTE WATER AND VENT SYSTEM (PLUMBING) 

 

	 	•	 	One 1” cold water line, two  3⁄4” hot water lines, a sanitary waste and vent on every floor for Tenant’s use. All
plumbing required for TIs, including any break areas, are to be installed by Tenant as part of TIs. 

  

	 	•	 	An ADA accessible drinking water refrigerated fountain is installed on each floor. 

 HVAC SYSTEM 

 

	 	•	 	Four (4) 110 ton roof mounted direct expansion VAV air cooled package Trane units have been provided with energy management controls, horizontal roof duct connections to units and vertical shafts to each floor are
provided by Landlord as part of the Base Building. Supply and exhaust ductwork and air outlets for warm shell “core” areas such as the lobby and restrooms are also provided as part of the Base Building. DDC system (with control wiring,
sensors, thermostats and control panels for core areas only) is provided for the Base Building HVAC system only, with the availability of the addition of DDC controls for future tenant improvements. 

 

	 	•	 	Rooftop boiler and hot water line vertically distributed to each floor are included in the Base Building. 

  

	 	•	 	Low pressure system designed by Landlord’s mechanical engineer in accordance with industry standards for open office use. 

  

	 	•	 	Building is designed for return air plenum. 

  

	 	•	 	Tenant to install all additional exhaust and HVAC systems related to TIs. The building energy management system is a Distech Controls branded Tridium AX open platform. Tenant is required to connect to the base building
system. 

 SUPPLEMENTAL and 24 hour HVAC 

 

	 	•	 	Supplied by Tenant in TI construction. Landlord has provided a rooftop equipment pad within Landlord’s roof screen area for Tenant’s supplemental HVAC units. Landlord to work with tenant to find additional
rooftop space and outdoor space to locate Tenant’s additional HVAC equipment. 

 ELECTRICAL AND POWER SYSTEM 

 

	 	•	 	An upgraded SVP transformer providing 4,000 amps to be installed, subject to SVP, sufficient for typical office electrical requirements plus Tenant’s ground floor lab requirements. Each floor has a separate 175A
277/480V 3PH feeder to a lighting Panel (3.05 VA/ft2) and a 150 amp step-down transformer with a 500A 120/208V 3PH Power Panel (3.78 VA/ft2). 

  

	 	•	 	Receptacles provided in the restrooms and exit corridors. 

  

	 	•	 	Downlights provided in the restroom and stairs/exit corridors. 

  

	 	•	 	Each building/tenant is to be separately metered. Landlord will coordinate with the utility companies to have meter installed at Landlord’s cost. Tenant to install submeters as needed and connect to the base
building energy management system. 

  

	 	•	 	No Emergency/Backup Power Supply and/or Generators will be supplied by Landlord. Landlord has provided conduit from the electrical room to exterior of building for future Tenant installed generator. 

 

	 	•	 	Emergency elevator service not included. Elevators in fail safe mode and return to ground floor. 

  

	 	•	 	Egress lighting is battery back-up. 

 FIRE & LIFE SAFETY SYSTEMS 

 

	 	•	 	Major fire line throughout the buildings with sprinkler heads pointing up in unfinished interior space. Complete sprinkler assembly in finished restrooms and stairwells. Fire monitoring system for base building with
core; tenant to expand as part of TIs. 

  

	 	•	 	Monitoring provided for sprinklers, elevators and HVAC base building and core systems per code. Tenant to expand monitoring for TI. 

  

	 	•	 	Landlord provided code required fire alarm sounding devices and strobe lights in base building and core areas. 

SECURITY ACCESS SYSTEMS 
  

	 	•	 	None provided. Supplied by Tenant in TI construction if desired by Tenant. 

 TELECOMMUNICATION 

 

	 	•	 	Multi-telecommunication service providers enter building through an MPOE via a joint trench. 

  
 Exhibit D 

 Building C 
  

	 	•	 	An MPOE, feeder duct and service from the telephone company is provided to ground floor teledata/IT room adjacent to Landlord’s ground floor electrical room. Tenant responsible for distribution of its teledata/IT
within the building. 

  

	 	•	 	Landlord provided four 4” conduits into the ground floor MPOE room from central telecom vaults which connect to Landlord’s other buildings. 

 

	 	•	 	Landlord will provide roof top space for Tenant’s satellite dish. Tenant responsible for installing its satellite dish. 

PARKING 
  

	 	•	 	Landlord installed all surface parking, subject to modifications per Aruba Networks Bld D site plan. 

LANDSCAPE 
  

	 	•	 	Landlord has provided landscape and hardscape at all common areas surrounding the building and parking area and permanently installed seating and waste container. 

 

	 	•	 	Two bocce courts, one half sport court and outdoor dining/seating areas are provided. 

  

	 	•	 	A total 76 bike lockers have been provided for use by Buildings A, B, and C. 

  

	 	•	 	Conduit has been installed from the electrical room to the parking lot for future tenant EV charging stations. 

  

	 	•	 	All landscaped path of pedestrian travel areas are lighted and irrigated with electrically controlled automatic systems. 

LOADING DOCK 
  

	 	•	 	No loading docks are provided. Tenant to install a grade level loading area with double doors in area noted on the site plan. 

  

	 	•	 	Space for a tenant emergency generator is provided. 

  

	 	•	 	No trash compactor. Should Tenant desire a trash compactor, Landlord will install at Tenant’s costs. 

  
 Exhibit D 

 Building C 
  

EXHIBIT B TO WORK LETTER 

FORM OF CONSENT TO ASSIGNMENT 

This CONSENT TO ASSIGNMENT (“Consent”) is dated as of this
     day of             , 2015, by                     , a
                     ([“Tenant Improvement Architect”/“Tenant Improvement Contractor”/“Tenant Improvement Project
Manager”/Other Consultant]), in favor of                      Office Partners Holding Company LLC, a California limited
liability company (“Landlord”). 
 RECITALS 

A. Landlord and
                    , a                     
(“Tenant”) entered into that certain Lease Agreement dated as of             , 201     (the “Lease”) for premises located in the City
of                     , County of
                    , State of California, commonly known as or otherwise described as
                     Road, Suite     ,
                    , California; and 

B. Exhibit D to the Lease is a Work Letter pursuant to which Tenant has retained [Tenant Improvement Architect/Tenant Improvement
Contractor/Tenant Improvement Project Manager/Other Consultant]. 
 AGREEMENT 

NOW THEREFORE, for good and valuable consideration, the receipt and sufficiency of which
are hereby acknowledged, [Tenant Improvement Architect/Tenant Improvement Contractor/Tenant Improvement Project Manager/Other Consultant] hereby consents to the assignment effected by Paragraph 7 of the Work Letter. 

IN WITNESS WHEREOF, [Tenant Improvement Architect/Tenant Improvement Contractor/Tenant
Improvement Project Manager/Other Consultant] has executed this Consent as of the date first written above. 
  

							
	—		[TENANT IMPROVEMENT ARCHITECT/TENANT IMPROVEMENT CONTRACTOR/TENANT IMPROVEMENT
PROJECT MANAGER/OTHER CONSULTANT]
	—		 —

—
		By:		  

			—		Title:		  

	—		 —

—
		By:		  

			—		Title:		  

  
 Exhibit D 

 Building C 
  

EXHIBIT E 
 LEASE
COMMENCEMENT DATE CERTIFICATE 
 This LEASE COMMENCEMENT CERTIFICATE (“Certificate”) is made this
                     day of                     ,
201    , by and between                      (“Landlord”), and
                    , a                     
(“Tenant”), and is attached to and made a part of that certain Lease dated as of                     , 201    ,
by and between Landlord and Tenant (the “Lease”). 
  

Landlord and Tenant hereby acknowledge and agree for all purposes of the Lease that: 

 

	1.	Tenant has accepted possession of the Leased Premises and formally accepts the same and acknowledges that the Leased Premises are in the condition called for by the Lease (including the Work Letter). 

 

	2.	the Lease Commencement Date as defined in Paragraph 2.3 of the Lease is             , 201    , 

IN WITNESS WHEREOF, Landlord and Tenant have executed this Certificate on the date first above written. 

 

									
	TENANT:
	
	ARUBA NETWORKS, INC., a Delaware corporation
	
	By:
                                         
                                         
  
	Printed Name:
                                         
                         
	Title:
                                         
                                        

	
	By:
                                         
                                         
  
	Printed Name:
                                         
                         
	Title:
                                         
                                        

	
	LANDLORD:

  

			
	SANTA CLARA CAMPUS PROPERTY OWNER I LLC, a Delaware limited liability company
		
	 By:
		 Santa Clara Campus Partners LLC,
 a Delaware
limited liability company,
 its Sole Member

					
			
			   By:
		 Menlo Equities Development Company IX LLC,
 a
California limited liability company, its Manager

							
				
					 By:
		 Menlo Equities V LLC, a California limited liability company, its Manager

									
					
							  By:
		 Menlo Legacy Holdings L.P.,
 a California
limited partnership,
 its Managing Member

															
						
											    By:
                                        

											    Henry D. Bullock, President

  
 Exhibit E 

 Building C 
  

EXHIBIT F 
 [RESERVED]

  

  
 Exhibit F 

 Building C 
  

EXHIBIT G 
 FORM OF LUMP
SUM PAYMENT AMENDMENT 
 AMENDMENT NO.      TO LEASE 

This AMENDMENT TO LEASE (“Amendment”) is dated as of this
    day of             , 201     (the “Amendment Date”), by and between
                     LLC, a California limited liability company (“Landlord”), and
                    , a                     
(“Tenant”). 
 RECITALS 

A. Landlord and Tenant entered into that certain Lease dated as of
            , 201     [as amended by that certain
                     dated as of
                    ] (collectively, the “Lease”) for premises located in the City of Santa Clara, County of Santa Clara, State of
California, commonly known as or otherwise described as                      Street, Suite
                    ,                     ,
California, comprised of approximately                      rentable square feet of floor area as more particularly described in the Lease; and 

B. Landlord has exercised the Lump Sum Payment Option as defined in Paragraph 3.1(b) of the Lease. 

C. Landlord and Tenant now desire to amend the Lease to set forth the on the terms and conditions set forth herein. 

AGREEMENT 

NOW THEREFORE, for good and valuable consideration, the receipt and sufficiency of which
are hereby acknowledged, Landlord and Tenant hereby agree as follows: 
 1. Definitions. All capitalized terms used in this Amendment but not
otherwise defined shall have the meanings assigned to them in the Lease. 
 2. Lump Sum Payment Date. The Lump Sum Payment Date is
            , 201    . 
 3. Base Monthly Rent Start Date. The Base
Monthly Rent Start Date is             , 201    . 
 4. Abated Rent Lump
Sum Payment. The amount of the Abated Rent Lump Sum Payment is                      Dollars ($        ).

 5. Base Monthly Rent. The schedule of Base Monthly Rent, as set forth in Article 1 of the Lease, is hereby amended in its entirety to read as
follows: 
  

			
	 Period
	  	Base Monthly Rent
	 [Months    -    
	  	$0.00
	 Months     **-9
	  	$101,850.90]
	 Months 10-24
	  	$101,850.90
	 Months 25-36
	  	$104,142.55
	 Months 37-48
	  	$106,485.75
	 Months 49-60
	  	$108,881.68
	 Months 61-72
	  	$111,331.52
	 Months 73-84
	  	$113,836.48
	 Months 85-96
	  	$116,397.80
	 Months 97-108
	  	$119,016.75
	 Months 109-120
	  	$121,694.63
	 Months 121-132
	  	$124,432.76

 **[DRAFTING NOTE: COMPLETE TO CORRESPOND WITH BASE MONTHLY RENT START DATE AND CONFORM THE FIRST ROW IN THE SCHEDULE; IF BASE
MONTHLY RENT START DATE IS MONTH 1, DELETE THE FIRST ROW IN THE SCHEDULE.] 
 6. Ratification. The Lease, as amended by this Amendment, is hereby
ratified by Landlord and Tenant and Landlord and Tenant hereby agree that the Lease, as so amended, shall continue in full force and effect. 
 7.
Miscellaneous. 

  
 Exhibit G 

 Building C 
  

7.1 Voluntary Agreement. The parties have read this Amendment and the mutual releases contained in it, and on the advice of counsel they
have freely and voluntarily entered into this Amendment. 
 7.2 Attorney’s Fees. If either party commences an action against the
other party arising out of or in connection with this Amendment, the prevailing party shall be entitled to recover from the non-prevailing party, reasonable attorney’s fees and costs of suit. 

7.3 Successors. This Amendment shall be binding on and inure to the benefit of the parties and their successors. 

7.4 Counterparts. This Amendment may be signed in two or more counterparts. When at least one such counterpart has been signed by each
party, this Amendment shall be deemed to have been fully executed, each counterpart shall be deemed to be an original, and all counterparts shall be deemed to be one and the same agreement. 

IN WITNESS WHEREOF, Landlord and Tenant have executed this Amendment as of
the date first written above. 
 TENANT: 
  

	
	ARUBA NETWORKS, INC., a Delaware corporation
	
	By:                                     
                                         
      
	Printed Name:                                   
                               
	Title: President
	
	By:                                     
                                         
      
	Printed Name:                                   
                               
	Title: Chief Financial Officer
	
	LANDLORD:

  

			
	SANTA CLARA CAMPUS PROPERTY OWNER I LLC, a Delaware limited liability company
		
	 By:
		 Santa Clara Campus Partners LLC,
 a Delaware
limited liability company,
 its Sole Member

					
			
			   By:
		 Menlo Equities Development Company IX LLC,
 a
California limited liability company,
 its Manager

							
				
					 By:
		 Menlo Equities V LLC,

a California limited liability company,

its Manager

									
					
							  By:
		 Menlo Legacy Holdings L.P.,
 a California
limited partnership,
 its Managing Member

											
					
									By:                                   
           
									 Henry D. Bullock, President

  
 Exhibit G 

 Building C 
  

EXHIBIT H 
 BUILDING
SIGNAGE 
  
 

 

  
 Exhibit H 

 Building C 
  

 

  
 Exhibit H 

 Building C 
  

 

  
 Exhibit H 

 Building C 
  

EXHIBIT I 

SUBORDINATION, NONDISTURBANCE AND ATTORNMENT PROVISIONS 

RECORDING REQUESTED BY 
 AND WHEN RECORDED MAIL TO:

 Wells Fargo Bank, National Association 
 CRE – San
Francisco - Gold (AU #02961) 
 600 California Street, 17th Floor 

San Francisco, CA 94108 
 Attn: Colleen King 

Loan No.                      

 
  

 
 (Space Above For Recorder’s Use)

 SUBORDINATION AGREEMENT, ACKNOWLEDGMENT OF LEASE ASSIGNMENT, 

ESTOPPEL, ATTORNMENT AND NON-DISTURBANCE AGREEMENT 

(Lease to Security Instrument) 
  

			
	NOTICE:		THIS SUBORDINATION AGREEMENT RESULTS IN YOUR SECURITY INTEREST IN THE PROPERTY BECOMING SUBJECT TO AND OF LOWER PRIORITY THAN THE LIEN OF SOME OTHER OR LATER SECURITY INSTRUMENT.

 THIS SUBORDINATION AGREEMENT, ACKNOWLEDGMENT OF LEASE ASSIGNMENT, ESTOPPEL, ATTORNMENT AND NON-DISTURBANCE AGREEMENT
(“Agreement”) is made [DATE] by and between [PROPERTY OWNER NAME], A(N) [ENTITY TYPE], OWNER(S) OF THE REAL PROPERTY HEREINAFTER DESCRIBED ([[collectively,]] “Mortgagor”), [TENANT NAME[
(“Tenant”) and Wells Fargo Bank, National Association (collectively with its successors or assigns, “Lender”). 

R E C I T A L S 
  

	A.	Pursuant to the terms and provisions of a lease dated [DATE OF LEASE] (“Lease”), Mortgagor granted to Tenant a leasehold estate in and to [[a portion of]] the property described on Exhibit
A attached hereto and incorporated herein by this reference (which property, together with all improvements now or hereafter located on the property, is defined as the “Property”). 

 

	B.	Mortgagor has executed, or proposes to execute, that certain Deed Of Trust (“Security Instrument”) securing, among other things, that certain Promissory Note dated [DATE OF NOTE]
(“Note”) in the principal sum of [LOAN AMOUNT ($NUMBERS)], in favor of Lender (“Loan”). The Security Instrument has been or will be recorded concurrently herewith in the real property records where the
Property is located. 

  

	C.	As a condition to Lender making the Loan secured by the Security Instrument, Lender requires that the Security Instrument be unconditionally and at all times remain a lien on the Property, prior and superior to all the
rights of Tenant under the Lease and that the Tenant specifically and unconditionally subordinate the Lease to the lien of the Security Instrument. 

  

	D.	Mortgagor and Tenant have agreed to the subordination, attornment and other agreements herein in favor of Lender. 

NOW THEREFORE, for valuable consideration and to induce Lender to make the Loan, Mortgagor and Tenant hereby agree for the benefit of Lender as follows: 

 

	(1)	SUBORDINATION. Mortgagor and Tenant hereby agree that: 

  

	 	1.	Prior Lien. The Security Instrument securing the Note in favor of Lender, and any modifications, renewals or extensions thereof (including, without limitation, any modifications, renewals or extensions with
respect to any additional advances made subject to the Security Instrument), shall unconditionally be and at all times remain a lien on the Property prior and superior to the Lease; 

 

	 	2.	Subordination. Lender would not make the Loan without this agreement to subordinate; and 

  
 Exhibit I 

 Building C 
  

 

	 	3.	Whole Agreement. This Agreement shall be the whole agreement and only agreement with regard to the subordination of the Lease to the lien of the Security Instrument and shall supersede and cancel, but only
insofar as would affect the priority between the Security Instrument and the Lease, any prior agreements as to such subordination, including, without limitation, those provisions, if any, contained in the Lease which provide for the subordination of
the Lease to a deed or deeds of trust or to a mortgage or mortgages. 

 AND FURTHER, Tenant individually declares, agrees and acknowledges for
the benefit of Lender, that: 
  

	 	4.	Use of Proceeds. Lender, in making disbursements pursuant to the Note, the Security Instrument or any loan agreements with respect to the Property, is under no obligation or duty to, nor has Lender represented
that it will, see to the application of such proceeds by the person or persons to whom Lender disburses such proceeds, and any application or use of such proceeds for purposes other than those provided for in such agreement or agreements shall not
defeat this agreement to subordinate in whole or in part; and 

  

	 	5.	Waiver, Relinquishment and Subordination. Tenant intentionally and unconditionally waives, relinquishes and subordinates all of Tenant’s right, title and interest in and to the Property to the lien of the
Security Instrument and understands that in reliance upon, and in consideration of, this waiver, relinquishment and subordination, specific loans and advances are being and will be made by Lender and, as part and parcel thereof, specific monetary
and other obligations are being and will be entered into which would not be made or entered into but for said reliance upon this waiver, relinquishment and subordination. 

 

	(2)	ASSIGNMENT. Tenant acknowledges and consents to the assignment of the Lease by Mortgagor in favor of Lender. 

  

	(3)	ESTOPPEL. Tenant acknowledges and represents that: 

  

	 	1.	Entire Agreement. The Lease constitutes the entire agreement between Mortgagor and Tenant with respect to the Property and Tenant claims no rights with respect to the Property other than as set forth in the
Lease; 

  

	 	2.	No Prepaid Rent. No deposits or prepayments of rent have been made in connection with the Lease, except as follows (if none, state “None”):
                                         
                                         
                                         
                                         
                                         
                                         
                              ; 

 

	 	3.	No Default. To the best of Tenant’s knowledge, as of the date hereof: (i) there exists no breach, default, or event or condition which, with the giving of notice or the passage of time or both, would
constitute a breach or default under the Lease; and (ii) there are no existing claims, defenses or offsets against rental due or to become due under the Lease; 

 

	 	4.	Lease Effective. The Lease has been duly executed and delivered by Tenant and, subject to the terms and conditions thereof, the Lease is in full force and effect, the obligations of Tenant thereunder are valid
and binding and there have been no [[further]] amendments, modifications or additions to the Lease, written or oral; and 

  

	 	5.	No Broker Liens. Neither Tenant nor Mortgagor has incurred any fee or commission with any real estate broker which would give rise to any lien right under state or local law, except as follows (if none, state
“None”):                     . 

  

	(4)	ADDITIONAL AGREEMENTS. Tenant covenants and agrees that, during all such times as Lender is the Beneficiary under the Security Instrument: 

 

	 	1.	Modification, Termination and Cancellation. Tenant will not consent to any modification, amendment, termination or cancellation of the Lease (in whole or in part) except in accordance with its terms without
Lender’s prior written consent and will not make any payment to Mortgagor in consideration of any modification, termination or cancellation of the Lease (in whole or in part) other than in accordance with its terms, including but not limited to
amendments referenced in the Lease as necessary for the operation of the terms thereof without Lender’s prior written consent; 

  

	 	2.	 Notice of Default. Tenant will notify Lender in writing concurrently with any notice given to Mortgagor of any default by Mortgagor under the
Lease, and Tenant agrees that Lender has the right (but not the obligation) to cure any breach or default specified in such notice within the time periods set forth below and Tenant will not declare a default of the Lease, as to Lender, if Lender

  
 Exhibit I 

 Building C 
  

	 	
cures such default within fifteen (15) days from and after the expiration of the time period provided in the Lease for the cure thereof by Mortgagor; provided, however, that if
such default cannot with diligence be cured by Lender within such fifteen (15) day period, the commencement of action by Lender within such fifteen (15) day period to remedy the same shall be deemed sufficient so long as Lender pursues
such cure with diligence. 

  

	 	3.	No Advance Rents. Tenant will make no payments or prepayments of rent more than one (1) month in advance of the time when the same become due under the Lease. 

 

	 	4.	Assignment of Rents. Upon receipt by Tenant of written notice from Lender that Lender has elected to terminate the license granted to Mortgagor to collect rents, as provided in the Security Instrument, and
directing the payment of rents by Tenant to Lender, Tenant shall comply with such direction to pay and shall not be required to determine whether Mortgagor is in default under the Loan and/or the Security Instrument. In the event of such payments to
Lender, Mortgagor hereby releases Tenant from any claims Mortgagor may otherwise have for Tenant’s failure to pay rent to Mortgagor and agrees that any such payments shall be credited toward Tenant’s obligation to pay rent pursuant to the
terms of the Lease. 

  

	 	5.	Insurance and Condemnation Proceeds. In the event there is any conflict between the terms in the Security Instrument and the Lease regarding the use of insurance proceeds or condemnation proceeds with respect to
the Property, the provisions of the Security Instrument shall control. 

  

	(5)	ATTORNMENT. In the event of a foreclosure under the Security Instrument, Tenant agrees for the benefit of Lender (including for this purpose any transferee of Lender or any transferee of Mortgagor’s title in
and to the Property by Lender’s exercise of the remedy of sale by foreclosure under the Security Instrument) as follows: 

  

	 	1.	Payment of Rent. Tenant shall pay to Lender all rental payments required to be made by Tenant pursuant to the terms of the Lease for the duration of the term of the Lease; 

 

	 	2.	Continuation of Performance. Tenant shall be bound to Lender in accordance with all of the provisions of the Lease for the balance of the term thereof, and Tenant hereby attorns to Lender as its landlord, such
attornment to be effective and self-operative without the execution of any further instrument immediately upon Lender succeeding to Mortgagor’s interest in the Lease and giving written notice thereof to Tenant; 

 

	 	3.	No Offset. Lender shall not be liable: (i) for, nor subject to, any offsets or defenses which Tenant may have by reason of any act or omission of Mortgagor under the Lease, except by reason of any act or
omission continuing after foreclosure, or deed in lieu thereof, of which Lender had notice prior to foreclosure or deed in lieu thereof, and failed to cure within fifteen (15) days from and after the expiration of the time period provided in
the Lease for the cure thereof by Mortgagor, and which relates to the repair or maintenance of the Property; nor (ii) for the return of any sums which Tenant may have paid to Mortgagor under the Lease as and for security deposits, advance
rentals or otherwise, except to the extent that such sums are actually delivered by Mortgagor to Lender; and 

  

	 	4.	Subsequent Transfer. If Lender, by succeeding to the interest of Mortgagor under the Lease, should become obligated to perform the covenants of Mortgagor thereunder, then, upon any further transfer of
Mortgagor’s interest by Lender, all of such unaccrued obligations shall terminate as to Lender. 

  

	 	5.	Limitation on Lender’s Liability. Tenant agrees to look solely to Lender’s interest in the Property and the rent, income or proceeds derived therefrom for the recovery of any judgment against Lender,
and in no event shall Lender or any of its affiliates, officers, directors, shareholders, partners, agents, representatives or employees ever be personally liable for any such obligation, liability or judgment. 

 

	 	6.	No Representation, Warranties or Indemnities. Lender shall not be liable with respect to any representations, warranties or indemnities from Mortgagor, whether pursuant to the Lease or otherwise, including, but
not limited to, any representation, warranty or indemnity related to the use of the Property, compliance with zoning, landlord’s title, landlord’s authority, habitability or fitness for purposes or commercial suitability, or hazardous
wastes, hazardous substances, toxic materials or similar phraseology relating to the environmental condition of the Property or any portion thereof. 

  

	(6)	NON-DISTURBANCE. In the event of a foreclosure under the Security Instrument, so long as there shall then exist no breach, default, or event of default on the part of Tenant under the Lease, Lender agrees for
itself and its successors and assigns that the leasehold interest of Tenant under 

  
 Exhibit I 

 Building C 
  

	 	
the Lease shall not be extinguished or terminated by reason of such foreclosure, but rather the Lease shall continue in full force and effect in accordance with the terms thereof and Lender shall
recognize and accept Tenant as tenant under the Lease subject to the terms and provisions of the Lease except as modified by this Agreement; provided, however, that Tenant and Lender agree that the following provisions of the Lease (if
any) shall not be binding on Lender: any option to purchase with respect to the Property; or any right of first refusal with respect to the Property; or any provision regarding the use of insurance proceeds or condemnation proceeds with respect to
the Property which is inconsistent with the terms of the Security Instrument. 

  

	(7)	MISCELLANEOUS. 

  

	1.	Remedies Cumulative. All rights of Lender herein to collect rents on behalf of Mortgagor under the Lease are cumulative and shall be in addition to any and all other rights and remedies provided by law and by
other agreements between Lender and Mortgagor or others. 

  

	2.	NOTICES. All notices, demands, or other communications under this Agreement and the other Loan Documents shall be in writing and shall be delivered to the appropriate party at the address set forth below (subject
to change from time to time by written notice to all other parties to this Agreement). All notices, demands or other communications shall be considered as properly given if delivered personally or sent by first class United States Postal Service
mail, postage prepaid, or by Overnight Express Mail or by overnight commercial courier service, charges prepaid, except that notice of Default may be sent by certified mail, return receipt requested, charges prepaid. Notices so sent shall be
effective three (3) Business Days after mailing, if mailed by first class mail, and otherwise upon delivery or refusal; provided, however, that non-receipt of any communication as the result of any change of address of which the
sending party was not notified or as the result of a refusal to accept delivery shall be deemed receipt of such communication. For purposes of notice, the address of the parties shall be: 

 

			
	 Mortgagor:
		 [OWNER NAME
 STREE ADDRESS

CITY, STATE ZIP]
  

Attention: [CONTACT NAME]

		
	 Tenant:
		 [TENANT NAME
 TENANT ADDRESS 1

TENANT ADDRESS 2
 TENANT CITY, STATE ZIP]

 
 Attention: [TENANT CONTACT]

		
	 Lender:
		 Wells Fargo Bank, National Association
 CRE
– San Francisco Gold (AU #02961)
 420 Montgomery St., 6th Floor

San Francisco, CA
  

94104 Attention: Brett Kondrick
  

Loan #: [LOAN NO.]

		
	 With a copy to:
		 Wells Fargo Bank, National Association
 WLS
Minneapolis Loan Center
 608 2nd Avenue South, 11th Floor

Minneapolis, MN 55402
  

Attention: James Fransen

 Any party shall have the right to change its address for notice hereunder to any other location within the
continental United States by the giving of thirty (30) days’ notice to the other party in the manner set forth hereinabove. 
  

	 	3.	Heirs, Successors and Assigns. Except as otherwise expressly provided under the terms and conditions herein, the terms of this Agreement shall bind and inure to the benefit of the heirs, executors,
administrators, nominees, successors and assigns of the parties hereto. 

  

	 	4.	Headings. All article, section or other headings appearing in this Agreement are for convenience of reference only and shall be disregarded in construing this Agreement. 

  
 Exhibit I 

 Building C 
  

	 	5.	Counterparts. To facilitate execution, this document may be executed in as many counterparts as may be convenient or required. It shall not be necessary that the signature of, or on behalf of, each party, or that
the signature of all persons required to bind any party, appear on each counterpart. All counterparts shall collectively constitute a single document. It shall not be necessary in making proof of this document to produce or account for more than a
single counterpart containing the respective signatures of, or on behalf of, each of the parties hereto. Any signature page to any counterpart may be detached from such counterpart without impairing the legal effect of the signatures thereon and
thereafter attached to another counterpart identical thereto except having attached to it additional signature pages. 

  

	 	6.	Exhibits, Schedules and Riders. All exhibits, schedules, riders and other items attached hereto are incorporated into this Agreement by such attachment for all purposes. 

IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the day and year first above written. 

NOTICE: THIS SUBORDINATION AGREEMENT CONTAINS A PROVISION WHICH ALLOWS THE PERSON OBLIGATED ON YOUR REAL PROPERTY SECURITY TO OBTAIN A LOAN A PORTION OF
WHICH MAY BE EXPENDED FOR OTHER PURPOSES THAN IMPROVEMENT OF THE LAND. 
 IT IS RECOMMENDED THAT, PRIOR TO THE EXECUTION OF THIS AGREEMENT, THE PARTIES
CONSULT WITH THEIR ATTORNEYS WITH RESPECT HERETO. 

  
 Exhibit I 

 Building C 
  

“MORTGAGOR” 
 [[SIGNATURE BLOCK FOR PROPERTY
MORTGAGOR(S)]] 
 “TENANT” 
 [[SIGNATURE BLOCK
FOR TENANT]] 
 “LENDER” 
 WELLS FARGO BANK,

 NATIONAL ASSOCIATION 
  

			
	 By:
		  

	 Name:
		  

	 Its:
		  

 (IF DOCUMENT TO BE RECORDED, ALL SIGNATURES 

MUST BE ACKNOWLEDGED) 

  
 Exhibit I 

 Building C 
  

EXHIBIT A - DESCRIPTION OF PROPERTY 

[[TO BE ATTACHED]] 

  
 Exhibit I 

 Building C 
  

[[IF LEASE GUARANTY]] LEASE GUARANTOR’S CONSENT 

The undersigned (“Lease Guarantor”) consents to the foregoing [[Subordination Agreement]] [[Subordination Agreement; Acknowledgment of
Lease Assignment, Estoppel, Attornment and Non-Disturbance Agreement]] [[Acknowledgment of Lease Assignment, Estoppel, Attornment and Non-Disturbance Agreement]] and the transactions contemplated thereby and reaffirms its obligations under the lease
guaranty (“Lease Guaranty”) dated LEASE GUARANTY DATE. Lease Guarantor further reaffirms that its obligations under the Lease Guaranty are separate and distinct from Tenant’s obligations. 

AGREED: 
 Dated as of:
                                         
                                

“LEASE GUARANTOR” 
 [[SIGNATURE BLOCK FOR LEASE
GUARANTOR]] 
 (IF DOCUMENT TO BE RECORDED, ALL SIGNATURES 

MUST BE ACKNOWLEDGED) 

  
 Exhibit I 

 Building C 
  

EXHIBIT J 
 FORM OF
ESTOPPEL CERTIFICATE 
  

			
			            , 20            
	
	  

	
	  

	
	  

	
	  

		
	Re		  

			                    , California

 Ladies and Gentlemen: 

Reference is made to that certain Lease, dated as of
                    , 20        , between
                     LLC, a California limited liability company (“Landlord”), and the undersigned (herein referred to as the
“Lease”). A copy of the Lease [and all amendment thereto] is[are] attached hereto as Exhibit A. At the request of Landlord in connection with
[                    State reasons for request for estoppel certificate
                    ], the undersigned hereby certifies to Landlord and to [state names of other parties requiring certification (e.g.,
lender, purchaser, investor)] (“Lender”/ “Purchaser”/ “Investor”) and each of your respective successors and assigns as follows: 

1. The undersigned is the tenant under the Lease. 

2. The Lease is in full force and effect and has not been amended, modified, supplemented or superseded except as indicated in Exhibit A. 

3. There is no defense, offset, claim or counterclaim by or in favor of the undersigned against Landlord under the Lease or against the
obligations of the undersigned under the Lease. The undersigned has no renewal, extension or expansion option, no right of first offer or right of first refusal and no other similar right to renew or extend the term of the Lease or expand the
property demised thereunder except as may be expressly set forth in the Lease. 
 4. All improvements to be constructed in the Leased
Premises by Landlord, if any, have been completed and accepted by Tenant, and any tenant construction or other allowances have been paid in full. [MODIFY OR DELETE, AS APPLICABLE, IF NOT CORRECT] 

5. The undersigned has no actual knowledge of any default now existing of the undersigned or of Landlord under the Lease, nor of any event
which with notice or the passage of time or both would constitute a default of the undersigned or of Landlord under the Lease. 
 6. The
undersigned has not received notice of a prior transfer, assignment, hypothecation or pledge by Landlord of any of Landlord’s interest in the Lease. 

7. The monthly rent due under the Lease is
$                    and has been paid through
                    , and all additional rent due and payable under the Lease has been paid through
                . 
 8. The term of the Lease commenced on
                    , and expires on
                    , unless sooner terminated pursuant to the provisions of the Lease. Landlord has performed all work required by the Lease for the
undersigned’s initial occupancy of the demised property. 
 9. The undersigned has deposited the sum of
$                    with Landlord as security for the performance of its obligations as tenant under the Lease, and no portion of such deposit has
been applied by Landlord to any obligation under the Lease. 
 10. There is no free rent period pending, nor is Tenant entitled to any
Landlord’s contribution. [MODIFY OR DELETE, AS APPLICABLE, IF NOT CORRECT] 
 The above certifications are made to Landlord and [Lender/ Purchaser/
Investor] knowing that Landlord and [Lender/ Purchaser/ Investor] will rely thereon in [making a loan secured in part by an assignment of the Lease/ accepting an assignment of the Lease/ investing in Landlord/other]. Tenant’s “actual
knowledge” means the current, actual knowledge of the person executing this document on behalf of Tenant, without any duty of investigation (other than inquiry of the appropriate personnel of Tenant who have responsibility for administration of
the Lease in accordance with Tenant’s standard procedures applicable to its leasing program). 

  
 Exhibit K 

 Building C 
  

Tenant’s certifications above are made solely to estop Tenant from asserting against the recipients named therein (other than Landlord), facts or claims
contrary to those stated herein, and such certifications shall be binding on Tenant vis-à-vis the recipients named herein (other than Landlord) but shall not modify in any way, Tenant’s relationship, obligations or rights
vis-à-vis Landlord. 
 Very truly yours, 
  

			
	  

	By:		
	Name:		
	Title:		

  
 Exhibit K 

 Building C 
  

EXHIBIT K-1 

MEMORANDUM OF LEASE 
 RECORDING
REQUESTED BY 
 AND WHEN RECORDED MAIL TO: 
 Aruba Networks,
Inc. 
 1344 Crossman Avenue 
 Sunnyvale, California 

Attn: Mr. Michael Phelps 

            Senior Director of Real Estate 

            and Facilities 

 
  

 
 APN: 

(Space Above For Recorder’s Use) 
 Short-Term
Lease 
 MEMORANDUM OF LEASE 

(3335 Scott Boulevard, Santa Clara, California) 

THIS MEMORANDUM OF LEASE (“Memorandum”) is entered into as of the
            day of April, 2015, by and between SANTA CLARA CAMPUS PROPERTY OWNER I LLC, a Delaware limited liability company (“Landlord”), and ARUBA NETWORKS, INC., a
Delaware corporation (“Tenant”). 
 1. Defined Terms; Exhibits. Unless otherwise set forth herein, all defined terms
used in this Memorandum shall have the same meanings ascribed thereto in the Lease (as defined below). All Exhibits referenced herein are attached hereto, and are incorporated herein by this reference. 

2. Premises. Landlord hereby leases to Tenant and Tenant hereby leases from Landlord, pursuant to the terms and conditions of that
certain Lease dated as of April         , 2015 (the “Lease”), those certain premises described in the Lease (the “Premises”), consisting of approximately 35,121 rentable
square feet of space, comprising the first floor of a four story building (the “Building”) known as Building C and located at 3315 Scott Boulevard in the City of Santa Clara, California, situated on the real property more
particularly described on Exhibit A to this Memorandum. Pursuant to the Lease, Landlord hereby also grants to Tenant the right to use the common areas of the Project in accordance with and as described in the Lease. 

3. Term. The term of the Lease (“Term”) is for a period of approximately one hundred thirty-two (132) months,
starting on the Commencement Date and ending one hundred thirty-two (132) months after the Lease Commencement Date, subject to adjustment as provided in the Lease. The Lease Commencement Date is expected to occur on or about March 1, 2017,
subject to adjustment as provided in the Lease. 

  
 Exhibit K 

 Building C 
  

4. Extension Options. Pursuant to the Lease, Landlord grants to Tenant two (2) consecutive options to extend the Term, each for a
period of five (5) years. 
 5. Right Of First Refusal to Lease; Right of First Offer to Lease. Pursuant to the Lease, Landlord
grants to Tenant an ongoing right of first refusal and an ongoing right of first offer to lease space on the second and third floors of the Building throughout the term of the Lease on terms and conditions more particularly described in Paragraphs
17.1 and 17.2 of the Lease. 
 6. Lease Incorporated. All the other terms, conditions and covenants of the Lease are incorporated
herein by this reference. This Memorandum is intended simply to provide notice of certain of the terms and provisions of the Lease, and in no way amends, modifies, or is to be used to interpret the Lease or any portions thereof. In the event of a
conflict between the provisions of this Memorandum and the provisions of the Lease, the provisions of the Lease shall govern. 
 7.
Counterparts. This Memorandum may be executed in counterparts, each of which shall be an original but all of which together shall constitute one and the same agreement. This Memorandum is solely for notice and recording purposes and shall not
be construed to alter, modify, expand, diminish or supplement the provisions of the Lease. 
 [SIGNATURES ON FOLLOWING PAGE] 

  
 Exhibit K 

 Building C 
  

IN WITNESS WHEREOF, this Memorandum has been duly executed by the parties hereto as of the day and year first above written. 

LANDLORD: 
  
  

			
	SANTA CLARA CAMPUS PROPERTY OWNER I LLC, a Delaware limited liability company
		
	 By:
		 Santa Clara Campus Partners LLC,
 a Delaware
limited liability company,
 its Sole Member

					
			
			   By:
		 Menlo Equities Development Company IX LLC,
 a
California limited liability company,
 its Manager

							
				
					 By:
		 Menlo Equities V LLC,

a California limited liability company,

its Manager

									
					
							  By:
		 Menlo Legacy Holdings L.P.,
 a California
limited partnership, its Managing Member

															
						
											 By:
                                    

											Henry Bullock, President

  

			
	 TENANT:

	
	 ARUBA NETWORKS, INC.,

a Delaware corporation

		
	 By:
		 
	 Name:
		 
	 Title:
		 

  
 Exhibit K 

 Building C 
  

State of California 
 County of
                    } ss. 
 On
                     before me,
                    , Notary Public, personally
appeared                    , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the
within instrument and acknowledged to me that he/she executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted,
executed the instrument. 
 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.

 WITNESS my hand and official seal. 
  

	
	  

	Signature

 (seal) 

State of California 
 County of
                    } ss. 
 On
                     before me,
                    , Notary Public, personally
appeared                    , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the
within instrument and acknowledged to me that he/she executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted,
executed the instrument. 
 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.

 WITNESS my hand and official seal. 
  

	
	  

	Signature

 (seal) 

  
 Exhibit K 

 Building C 
  

EXHIBIT A 
 Legal
Description of Premises 

  
 Exhibit K 

 Building C 
  

EXHIBIT K-2 
 TERMINATION
OF LEASE AND MEMORANDUM OF LEASE 
 RECORDING REQUESTED BY 

AND WHEN RECORDED MAIL TO: 
 Menlo Equities LLC 

490 California Street, 4th Floor 

Palo Alto, California 94306 
 Attn: Henry Bullock/Rick Holmstrom

  
  

 
 APN: 

(Space Above For Recorder’s Use) 
 Short-Term
Lease 
 TERMINATION OF LEASE AND MEMORANDUM OF LEASE 

(3335 Scott Boulevard, Santa Clara, California) 

THIS TERMINATION OF LEASE AND MEMORANDUM OF (“Termination Agreement”) is entered into as of the
            day of             , 2    , by and between SANTA CLARA CAMPUS PROPERTY OWNER I LLC, a Delaware
limited liability company (“Landlord”), and ARUBA NETWORKS, INC., a Delaware corporation (“Tenant”). 

Landlord and Tenant are parties to that certain (i) Lease dated as of April     , 2015 for the building located at
3315 Scott Boulevard in the City of Santa Clara, California, situated on the real property more particularly described on Exhibit A to this Partial Termination Agreement (the “Lease”). In connection with the Lease, Landlord
and Tenant are also parties to that certain Memorandum of Lease dated as of April     , 2015, recorded on             , 2015 in the Official Records of Santa Clara
County, California as Document No.             (the “Memorandum”). All of the terms and conditions of Lease were incorporated into the Memorandum. 

1. Unless otherwise set forth herein, all defined terms used in this Termination Agreement shall have the same meanings ascribed thereto in
the Lease. All Exhibits referenced herein are attached hereto, and are incorporated herein by this reference. 
 2. The Lease and the
Memorandum have expired or been terminated and are of no further force or effect. 
 3. Landlord and Tenant now desire to execute and record
this Termination Agreement in order to put the public on notice of the termination of the Lease. 
 4. This Termination Agreement may be
executed in counterparts, each of which shall be an original but all of which together shall constitute one and the same agreement. 

  
 Exhibit K 

 Building C 
  

IN WITNESS WHEREOF, this Partial Termination Agreement has been duly executed by the parties hereto as of the day and year first above written.

 LANDLORD: 
  

			
	SANTA CLARA CAMPUS PROPERTY OWNER I LLC, a Delaware limited liability company
		
	 By:
		 Santa Clara Campus Partners LLC,
 a Delaware
limited liability company,
 its Sole Member

					
			
			 By:
		 Menlo Equities Development Company IX LLC,
 a
California limited liability company,
 its Manager

							
				
					 By:
		 Menlo Equities V LLC,

a California limited liability company,

its Manager

									
					
							 By:
		Menlo Legacy Holdings L.P., a California limited partnership, its Managing Member

															
						
											  By:
                                        

											  Henry D. Bullock, President

  

					
	TENANT:
	
	 ARUBA NETWORKS, INC.,
 a
Delaware corporation

	
	By:
                                         
                                         
  
	Name:
                                         
                                     
	Title:
                                         
                                        

  
 Exhibit K 

 Building C 
  

State of California 
 County of
                    } ss. 
 On
                     before me,
                    , Notary Public, personally appeared
                    , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within
instrument and acknowledged to me that he/she executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the 
person(s), or the entity upon behalf of which the person(s) acted,
executed the instrument. 
 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.

 WITNESS my hand and official seal. 
  

	
	  

	Signature

 (seal) 

State of California 
 County of
                    } ss. 
 On
                     before me,
                    , Notary Public, personally appeared
                    , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within
instrument and acknowledged to me that he/she executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed
the instrument. 
 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. 

WITNESS my hand and official seal. 
  

	
	  

	Signature

 (seal) 

  
 Exhibit K 

 Building C 
  

EXHIBIT A 
 Legal
Description of Premises 

  
 Exhibit K 

 Building C 
  

EXHIBIT K-3 
 TERMINATION
OF CERTAIN RIGHTS UNDER LEASE 
 RECORDING REQUESTED BY 

AND WHEN RECORDED MAIL TO: 
 Menlo Equities LLC 

490 California Street, 4th Floor 

Palo Alto, California 94306 
 Attn: Henry Bullock/Rick Holmstrom

  
  

 
 APN: 

(Space Above For Recorder’s Use) 
 Short-Term
Lease 
 TERMINATION OF CERTAIN RIGHTS UNDER LEASE 

(3335 Scott Boulevard, Santa Clara, California) 

THIS TERMINATION OF CERTAIN RIGHTS UNDER LEASE (“Partial Termination Agreement”) is entered into as of the
         day of             , 2    , by and between SANTA CLARA CAMPUS PROPERTY OWNER I LLC, a Delaware limited liability company
(“Landlord”), and ARUBA NETWORKS, INC., a Delaware corporation (“Tenant”). 
 Landlord and Tenant are
parties to that certain (i) Lease dated as of April     , 2015 for the building located at 3315 Scott Boulevard in the City of Santa Clara, California, situated on the real property more particularly described on
Exhibit A to this Partial Termination Agreement (the “Lease”). In connection with the Lease, Landlord and Tenant are also parties to that certain Memorandum of Lease dated as of April     , 2015, recorded
on                     , 2015 in the Official Records of Santa Clara County, California as Document No.
                     (the “Memorandum”). All of the terms and conditions of Lease were incorporated into the Memorandum. 

1. Defined Terms; Exhibits. Unless otherwise set forth herein, all defined terms used in this Partial Termination Agreement shall have
the same meanings ascribed thereto in the Lease All Exhibits referenced herein are attached hereto, and are incorporated herein by this reference. 

2. Landlord granted to Tenant, pursuant to the Lease, certain lease rights more particularly described in the Lease. 

3. Tenant’s rights under Paragraph             and Paragraph
            of the Lease have terminated, and Landlord and Tenant hereby agree that each of such rights is now and hereafter shall be void and of no force or effect. 

4. Landlord and Tenant now desire to execute and record this Partial Termination Agreement in order to put the public on notice of the
termination of the Tenant’s rights under Paragraph             and Paragraph             of the Lease. 

5. Counterparts. This Partial Termination Agreement may be executed in counterparts, each of which shall be an original but all of
which together shall constitute one and the same agreement. 
 [SIGNATURES ON FOLLOWING PAGE] 

  
 Exhibit K 

 Building C 
  

IN WITNESS WHEREOF, this Partial Termination Agreement has been duly executed by the parties hereto as of the day and year first above written.

 LANDLORD: 
  

			
	SANTA CLARA CAMPUS PROPERTY OWNER I LLC, a Delaware limited liability company
		
	 By:
		 Santa Clara Campus Partners LLC,
 a Delaware
limited liability company,
 its Sole Member

					
			
			   By:
		 Menlo Equities Development Company IX LLC,
 a
California limited liability company,
 its Manager

							
				
					 By:
		 Menlo Equities V LLC,

a California limited liability company,

its Manager

									
					
							  By:
		 Menlo Legacy Holdings L.P.,
 a California
limited
 partnership,
 its Managing
Member

											
					
									By:                                   
           
									 Henry Bullock, President

  

	
	TENANT:
	
	 ARUBA NETWORKS, INC.,
 a
Delaware corporation

	
	By:                                     
                                         
      
	Name:                                     
                                         

	Title:                                     
                                         
  

  
 Exhibit K 

 Building C 
  

State of California 
 County of
            } ss. 
 On
                    before me,
                    , Notary Public, personally
appeared                    , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the
within instrument and acknowledged to me that he/she executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted,
executed the instrument. 
 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.

 WITNESS my hand and official seal. 
  

	
	
	  

	Signature

 (seal) 

State of California 
 County of
                    } ss. 
 On
                    before me,
                    , Notary Public, personally
appeared                    , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the
within instrument and acknowledged to me that he/she executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted,
executed the instrument. 
 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.

 WITNESS my hand and official seal. 
  

	
	
	   

	Signature

 (seal) 
  

  
 Exhibit K 

 Building C 
  

EXHIBIT A 
 Legal
Description of Premises 

  
 Exhibit KEX-10.2

 Exhibit 10.2 

Building D 
 LEASE 

BY AND BETWEEN 
 Santa
Clara Campus Property Owner I LLC, 
 a Delaware limited liability company 

as Landlord 
 and

 Aruba Networks, Inc., 

a Delaware corporation 

as Tenant 
 April 15,
2015 

 Building D 
  

TABLE OF CONTENTS 
  

							
	 	 	 	  	Page	 
			
	 ARTICLE 1
	 	 REFERENCE
	  	 	1	  
	 1.1
	 	References	  	 	1	  
			
	 ARTICLE 2
	 	 LEASED PREMISES, TERM AND POSSESSION
	  	 	7	  
	 2.1
	 	Demise Of Leased Premises	  	 	7	  
	 2.2
	 	Right To Use Common Areas	  	 	7	  
	 2.3
	 	Lease Commencement Date And Lease Term	  	 	8	  
	 2.4
	 	Delivery Of Possession	  	 	8	  
	 2.5
	 	Performance Of Tenant Improvement Work; Acceptance Of Possession	  	 	9	  
	 2.6
	 	Surrender Of Possession	  	 	9	  
			
	 ARTICLE 3
	 	 RENT
	  	 	11	  
	 3.1
	 	Base Monthly Rent	  	 	11	  
	 3.2
	 	Additional Rent	  	 	11	  
	 3.3
	 	Year-End Adjustments	  	 	12	  
	 3.4
	 	Late Charge, And Interest On Rent In Default	  	 	12	  
	 3.5
	 	Payment Of Rent	  	 	13	  
			
	 ARTICLE 4
	 	 USE OF LEASED PREMISES AND COMMON AREA
	  	 	13	  
	 4.1
	 	Permitted Use	  	 	13	  
	 4.2
	 	General Limitations On Use	  	 	13	  
	 4.3
	 	Noise And Emissions	  	 	13	  
	 4.4
	 	Trash Disposal	  	 	14	  
	 4.5
	 	Parking	  	 	14	  
	 4.6
	 	Signs	  	 	14	  
	 4.7
	 	Compliance With Laws And Restrictions	  	 	15	  
	 4.8
	 	Compliance With Insurance Requirements	  	 	15	  
	 4.9
	 	Landlord’s Right To Enter	  	 	15	  
	 4.10
	 	Use Of Common Areas	  	 	15	  
	 4.11
	 	Environmental Protection	  	 	16	  
	 4.12
	 	Rules And Regulations	  	 	17	  
	 4.13
	 	Reservations	  	 	17	  
			
	 ARTICLE 5
	 	 REPAIRS, MAINTENANCE, SERVICES AND UTILITIES
	  	 	18	  
	 5.1
	 	Repair And Maintenance	  	 	18	  
		 	(a) Tenant’s Obligations	  	 	18	  
		 	(b) Landlord’s Obligation	  	 	18	  
	 5.2
	 	Utilities	  	 	19	  
	 5.3
	 	Security	  	 	20	  
	 5.4
	 	Energy And Resource Consumption	  	 	20	  
	 5.5
	 	Limitation Of Landlord’s Liability	  	 	20	  
			
	 ARTICLE 6
	 	 ALTERATIONS AND IMPROVEMENTS
	  	 	21	  
	 6.1
	 	By Tenant	  	 	21	  
	 6.2
	 	Ownership Of Improvements	  	 	21	  
	 6.3
	 	Alterations Required By Law	  	 	21	  
	 6.4
	 	Liens	  	 	22	  
			
	 ARTICLE 7
	 	 ASSIGNMENT AND SUBLETTING BY TENANT
	  	 	22	  
	 7.1
	 	By Tenant	  	 	22	  
	 7.2
	 	Merger, Reorganization, or Sale of Assets	  	 	23	  
	 7.3
	 	Landlord’s Election	  	 	23	  
	 7.4
	 	Conditions To Landlord’s Consent	  	 	24	  
	 7.5
	 	Assignment Consideration And Excess Rentals Defined	  	 	25	  
	 7.6
	 	Payments	  	 	25	  
	 7.7
	 	Good Faith	  	 	25	  
	 7.8
	 	Effect Of Landlord’s Consent	  	 	25	  

  
 i 

 Building D 
  

							
	 ARTICLE 8
		 LIMITATION ON LANDLORD’S LIABILITY AND INDEMNITY
		 	27	  
	 8.1
		Limitation On Landlord’s Liability And Release		 	27	  
	 8.2
		Tenant’s Indemnification Of Landlord		 	27	  
			
	 ARTICLE 9
		 INSURANCE
		 	28	  
	 9.1
		Tenant’s Insurance		 	28	  
	 9.2
		Landlord’s Insurance		 	29	  
	 9.3
		Mutual Waiver Of Subrogation		 	29	  
			
	 ARTICLE 10
		 DAMAGE TO LEASED PREMISES
		 	29	  
	 10.1
		Landlord’s Duty To Restore		 	29	  
	 10.2
		Insurance Proceeds		 	29	  
	 10.3
		Landlord’s Right To Terminate		 	30	  
	 10.4
		Tenant’s Right To Terminate		 	30	  
	 10.5
		Tenant’s Waiver		 	31	  
	 10.6
		Abatement Of Rent		 	31	  
			
	 ARTICLE 11
		 CONDEMNATION
		 	31	  
	 11.1
		Tenant’s Right To Terminate		 	31	  
	 11.2
		Landlord’s Right To Terminate		 	31	  
	 11.3
		Restoration		 	31	  
	 11.4
		Temporary Taking		 	32	  
	 11.5
		Division Of Condemnation Award		 	32	  
	 11.6
		Abatement Of Rent		 	32	  
	 11.7
		Taking Defined		 	32	  
			
	 ARTICLE 12
		 DEFAULT AND REMEDIES
		 	32	  
	 12.1
		Events Of Tenant’s Default		 	32	  
	 12.2
		Landlord’s Remedies		 	33	  
	 12.3
		Landlord’s Default And Tenant’s Remedies		 	34	  
	 12.4
		Limitation Of Tenant’s Recourse		 	35	  
	 12.5
		Tenant’s Waiver		 	35	  
			
	 ARTICLE 13
		 GENERAL PROVISIONS
		 	35	  
	 13.1
		Taxes On Tenant’s Property		 	35	  
	 13.2
		Holding Over		 	36	  
	 13.3
		Subordination To Mortgages		 	36	  
	 13.4
		Tenant’s Attornment Upon Foreclosure		 	37	  
	 13.5
		Mortgagee Protection		 	37	  
	 13.6
		Estoppel Certificate		 	37	  
	 13.7
		Tenant’s Financial Information		 	38	  
	 13.8
		Transfer By Landlord		 	38	  
	 13.9
		Force Majeure		 	38	  
	 13.10
		Notices		 	38	  
	 13.11
		Attorneys’ Fees and Costs		 	39	  
	 13.12
		Definitions		 	39	  
			 (a)    Real Property Taxes
		 	39	  
			 (b)    Landlord’s Insurance Costs
		 	40	  
			 (c)    Property Maintenance Costs
		 	40	  
			 (d)    Property Operating Expenses
		 	41	  
			 (e)    Law
		 	44	  
			 (f)     Lender
		 	44	  
			 (g)    Rent
		 	44	  
			 (h)    Restrictions
		 	44	  
	 13.13
		General Waivers		 	44	  
	 13.14
		Miscellaneous		 	44	  
	 13.15
		Patriot Act Compliance		 	45	  
			
	 ARTICLE 14
		 LEGAL AUTHORITY BROKERS AND ENTIRE AGREEMENT
		 	46	  
	 14.1
		Legal Authority		 	46	  
	 14.2
		Brokerage Commissions		 	46	  

  
 ii 

 Building D 
  

							
	 14.3
		Entire Agreement		 	47	  
	 14.4
		Landlord’s Representations		 	47	  
			
	 ARTICLE 15
		 OPTIONS TO EXTEND
		 	47	  
	 15.1
		Option to Extend		 	47	  
	 15.2
		Fair Market Rent		 	48	  
	 15.3
		Tenant’s Election		 	48	  
	 15.4
		Rent Arbitration		 	48	  
			
	 ARTICLE 16
		 TELEPHONE SERVICE
		 	49	  

  
 iii 

 Building D 
  

LEASE 
 THIS LEASE,
dated April 15, 2015 for reference purposes only, is made by and between SANTA CLARA CAMPUS PROPERTY OWNER I LLC, a Delaware limited liability company
(“Landlord”) and ARUBA NETWORKS, INC., a Delaware corporation [NASDAQ: ARUN] (“Tenant”), to be effective and binding upon the parties as of the date the last of
the designated signatories to this Lease shall have executed this Lease (the “Effective Date of this Lease”). 
 ARTICLE
1 
 REFERENCE 

1.1 References. All references in this Lease (subject to any further clarifications contained in this Lease) to the following
terms shall have the following meaning or refer to the respective address, person, date, time period, amount, percentage, calendar year or fiscal year as below set forth: 
  

			
		
	Tenant’s Representative:		Michael Phelps
		
	Phone Number:		(408) 419-0296
		
	Landlord’s Representative:		Henry Bullock/Richard Holmstrom
		
	Phone Number:		(650) 326-9300
		
	Targeted Commencement Date:		March 1, 2017
		
	Intended Term:		One hundred thirty-two (132) months
		
	Lease Expiration Date:		One hundred thirty-two (132) months from the Lease Commencement Date (defined in Paragraph 2.3 below), unless earlier terminated in accordance with the terms of this Lease, or extended by Tenant pursuant to Paragraph 2.3 or
Article 15 below. Notwithstanding the foregoing or any other provision of this Lease, if the Lease Commencement Date is other than the first calendar day of a calendar month, then the Lease Expiration Date shall be one hundred thirty-two (132)
months from the last calendar day of the calendar month in which the Lease Commencement Date occurs, subject to the terms of Paragraph 2.3 and Article 15 below.
		
	Options to Extend:		Two (2) option(s) to extend, each for a term of five (5) years.
		
	Tenant’s Security Deposit:		None
		
	Late Charge Amount:		Five Percent (5%) of the Delinquent Amount
		
	Tenant’s Required Liability Coverage:		$5,000,000 Combined Single Limit
		
	Tenant’s Broker:		Jones Lang LaSalle
		
	Landlord’s Broker:		Colliers International
		
	Project:		That certain real property situated in the City of Santa Clara, County of Santa Clara, State of California, identified as Assessor’s Parcel Nos.:
		
			(1) 216-31-084, with a street address of 3355 Scott Boulevard (shown on the Site Plan as the location of “Building A”),
		
			(2) 216-31-085, with a street address of 3325 Scott Boulevard (shown on the Site Plan as the location of “Building B” and most of “Building D”),
		
			(3) 216-31-086, with a street address of 3315 Scott Boulevard (shown on the Site Plan as the location of “Building C” and the balance of “Building D” but which address will change after completion of the
adjustments described below in the definition if “Property,”),
		
			(4) 216-31-083, shown on the Site Plan as the location of future “Building E” and the future “Building F” with a current with a street address of 3335 Scott Boulevard.

  
 1 

 Building D 
  

			
		
			
		
			and
		
			(5) 216-31-082, with a current street address of 3345 Scott Boulevard (shown on the Site Plan as the location of the future “Parking Structure”), and such other buildings as Landlord may elect to construct in the
future,
		
			which real property is shown on the preliminary Site Plan attached hereto as Exhibit A (the “Site Plan”). Construction will commence on the Building after the Effective Date of this Lease. Future Building E
(“Building E”), future Building F (“Building F”), and future Parking Structure (“Parking Structure”) have not yet been constructed and Landlord may elect not to construct them; provided however that
if Landlord elects not to construct the Parking Structure, Landlord shall install surface parking sufficient to satisfy a parking ratio of 3.3 parking spaces per 1,000 rentable square feet of space constructed in the Project, and a minimum of 3.3
parking spaces for each 1,000 rentable square feet of Leased Premises shall continue to be located within the area depicted by a curved dotted line on Schedule 2.2(a) attached to the Lease. Landlord reserves the right to adjust the boundaries
of the Project and the sizes and locations of Building E, Building F, and the Parking Structure at any time, provided that the Required Conditions are satisfied. The Site Plan and Landlord’s proposed adjustments to it and the applicable
Assessor’s Parcel Map are subject to approval by the City of Santa Clara.
		
	Property:		Those certain separate legal parcels of real property currently identified as Assessor’s Parcel Nos. 216-31- 085 and 216-31-086, on which is situated the Building as delineated on the Site Plan. Landlord is currently
processing adjustments to the boundaries of the Property so that it will consist of a single legal parcel, and reserves the right to adjust the boundaries of the Property at any time, provided in all cases that the Required Conditions are
satisfied.
		
	Building:		That certain building to be constructed on the Property in which the Leased Premises will be located which, after the adjustments described in the prior paragraph, will have a street address of 3335 Scott Boulevard, Santa Clara,
California (the “Building”), which Building is shown outlined on the Site Plan (and denoted thereon as “Building D”), estimated to contain approximately 244,880 rentable square feet of space, which rentable square footage
will be determined by utilizing the Building Owners and Managers Association International Single Tenant Full Building Standard Method for Measuring Floor Area in Office Buildings ANSI Z65-1-1996, pages 10 and 11 (the “BOMA”), and
to which will be added a proportionate share of fitness center in the Other Building located at 3355 Scott Boulevard (the “Fitness Center”), which will be allocated across the rentable square footage of the Building and the Other
Buildings, bringing the total rentable square footage of the Building to approximately 245,804. Within thirty (30) days after the Final Base Building Plans (as defined in the Work Letter) have been approved by the City of Santa Clara, Landlord will
cause the Building to be measured off such plans in accordance with BOMA (and adding thereto the allocable square footage of the Fitness Center), and will provide the specifics of such calculations to Tenant, and the resulting rentable square
footage shall thereafter be the rentable square footage of the Building for all purposes under this Lease, unless Tenant elects to measure the Building as hereinafter set forth.

  
 2 

 Building D 
  

			
		
			If Tenant elects to measure, then Tenant shall cause its licensed architect or building measurement surveyor to calculate the rentable square footage of the Building off the Final Base Building Plans, employing BOMA (to which
will be added a proportionate share of Fitness Center as described above), and Tenant’s architect shall give written notice of such calculation and the specifics of such calculations to Landlord and Tenant within forty-five (45) days after
Tenant’s receipt of Landlord’s calculation. The parties shall then have ten (10) business days to reach agreement on the actual rentable square footage of the Building, failing which the matter shall be submitted to an architect mutually
agreed upon by Landlord and Tenant (the “Measurement Architect”). The rentable square footage of the Building as initially calculated by Landlord, or as agreed to by the parties, or as determined by submission to the Measurement
Architect, as applicable, shall thereafter be the rentable area of the Building for all purposes under this Lease (subject to any subsequent actual change in the physical area of the Building arising from a change in the Final Base Building Plans)
and the process of arriving at such rentable area shall be referred to below in some cases as the “Initial Measurement of the Building
		
	Other Buildings:		(a) Those certain buildings currently constructed in the Project (but outside the Property) commonly known as 3355 Scott Boulevard (“Building A”), containing approximately 144,499 rentable square feet of space,
3325 Scott Boulevard (“Building B”), containing approximately 157,412 rentable square feet of space, and 3315 Scott Boulevard (“Building C”), containing approximately 156,889 rentable square feet of space, as such
rentable square footage amounts were determined based on BOMA (to which has been added, or subtracted in the case of Building A, a proportionate share of Fitness Center as described above) and, for purposes of this Lease, agreed to contain said
number of rentable square feet, and (b) such other buildings as may be built on the Project from time to time.
		
	Building C Lease:		That certain Lease dated as of the date of this Lease, entered into by and between Landlord and Tenant for the first floor of Building C (the “Building C Lease”).
		
	Building C Premises:		The premises leased by Tenant pursuant to the Building C Lease (the “Building C Premises”).
		
	Common Areas:		The “Common Areas” shall mean the areas within the Building or the Project not reserved for the exclusive use of Landlord, Tenant or any other tenant, including, without limitation, lobbies, plazas, walkways,
private roadways, loading docks, parking areas, parking structures, and landscaped areas. Common Areas shall not include the interior of any Other Buildings, other than such portions thereof as Landlord may designate for the use of all occupants of
the Property.
		
	Parking:		With respect to the Leased Premises, Tenant shall be entitled to utilize 3.3 unreserved and unassigned parking spaces for each 1,000 rentable square feet of Leased Premises (as the same may change from time to time in accordance
with the terms of this Lease or an amendment hereto), such spaces to be located in the parking area of the Common Areas. For the avoidance

  
 3 

 Building D 
  

			
		
			of confusion, if the Leased Premises contain 204,837 rentable square feet of Leased Premises, Tenant would be entitled to 676 such parking spaces. Tenant may (within sixty (60) days after the Effective Date of this Lease, if at
all) designate up to fourteen (14) site standard parking spaces (out of Tenant’s overall parking count described above) within the area noted on the Site Plan as “Available Exclusive Parking Area,” for Tenant’s exclusive use so
long as it is in occupancy of the entire initial Leased Premises (“Tenant’s Exclusive Parking Spaces”). In addition, if Tenant so desires, Tenant may elect (within sixty (60) days after the Effective Date of this Lease, if at
all) to have Landlord designate up to an additional eight (8) site standard parking spaces (out of Tenant’s overall parking count described above) to be for Tenant’s exclusive use so long as it is in occupancy of the entire initial Leased
Premises (“Tenant’s Additional Exclusive Parking Spaces”). In the event Tenant at any time leases less than the entire initial Leased Premises, the number of Tenant’s Exclusive Parking Spaces and Tenant’s Additional
Exclusive Parking Spaces shall be proportionately reduced. Parking is provided to Tenant by Landlord without additional charge for the entire Lease Term including any expansion and/or extension periods, including but not limited to the First
Extension Period and the Second Extension Period (as defined in Article 15 below).
		
	Required Conditions:		The term “Required Conditions” is defined in Paragraph 2.2(a) below).
		
	Building Standard Hours:		The term “Building Standard Hours” means from 7:00 a.m. and 7:00 p.m. Monday through Friday and on Saturdays from 8:00 a.m. to noon, excluding Sundays and New Year’s Day, Presidents Day, Memorial Day,
Independence Day, Labor Day, Thanksgiving, Christmas and such other holidays as are generally recognized in the vicinity of the Project.
		
	HVAC:		Heating, ventilating, and/or air conditioning.
		
	Leased Premises:		The space located on the first, second, third, fourth, and fifth floors of the Building and shown on the floor plan attached hereto as Exhibit B, plus the load factor associated therewith, estimated to contain
approximately 204,837 rentable square feet, which rentable square footage has been determined by utilizing Landlord’s method of measurement (the “Premises Measurement Method”), which has been explained to Tenant, which is
illustrated in an exhibit attached to the Building C Lease (and which , for purposes of this Lease, will be modified to exclude the allocation of cafeteria square footage). Such rentable area calculation includes, without limitation, a proportionate
share of the common Building lobby, and the Fitness Center allocated across the rentable square footage of the Building and Buildings A, B, and C. Within forty-five (45) days after the Final Base Building Plans (as defined in the Work Letter) have
been approved by the City of Santa Clara, Landlord will cause the Leased Premises to be measured off such plans in accordance with the Premises Measurement Method, and will provide the specifics of such calculations to Tenant, and the resulting
rentable square footage shall thereafter be the rentable square footage of the Leased Premises for all purposes under this Lease, unless Tenant elects to measure the Leased

  
 4 

 Building D 
  

			
			Premises as hereinafter set forth.
		
			If Tenant elects to measure, then Tenant shall cause its licensed architect or building measurement surveyor to calculate the rentable square footage of the Leased Premises off the Final Base Building Plans, employing the
Premises Measurement Method, and Tenant’s architect shall give written notice of such calculation and the specifics of such calculations to Landlord and Tenant within thirty (30) days after Tenant’s receipt of the Landlord’s
Architect’s calculation. The parties shall then have ten (10) business days to reach agreement on the actual rentable square footage of the Leased Premises, failing which the matter shall be submitted to the Measurement Architect. The rentable
square footage of the Leased Premises as initially calculated by Landlord, or as agreed to by the parties, or as determined by submission to the Measurement Architect, as applicable, shall thereafter be the rentable area of the Leased Premises for
all purposes under this Lease (subject to any subsequent actual change in the physical area of the Leased Premises arising from a change in the Final Base Building Plans), and the process of arriving at such rentable area shall be referred to below
in some cases as the “Initial Measurement of the Leased Premises.”
		
	Work Letter:		The term “Work Letter” shall mean the Work Letter attached as Exhibit D to and made a part of this Lease, the terms and provisions of which are hereby incorporated into this Lease.
		
	Tenant’s Building Share:		The term “Tenant’s Building Share” shall mean the percentage obtained by dividing the rentable square footage of the Leased Premises at the time of calculation by the rentable square footage of the Building
at the time of calculation. Such percentage is currently estimated to be 83.33%, but is subject to adjustment based on the Initial Measurement of the Leased Premises and the Initial Measurement of the Building. In the event that the rentable square
footage of the Leased Premises or the Building is changed (other than by mere re-measurement after the Initial Measurement of the Leased Premises and the Initial Measurement of the Building), Tenant’s Building Share shall be recalculated to
equal the percentage described in the first sentence of this paragraph, so that the aggregate Tenant’s Building Share of all tenant space in the Building shall equal 100% (calculated as if the Building were fully occupied). Landlord and Tenant
agree that any mere re-measurement (occurring after the Initial Measurement of the Leased Premises and the Initial Measurement of the Building), as opposed to an actual physical change, shall not result in a change in rentable square
footage.
		
	Tenant’s Project Share:		The term “Tenant’s Project Share” shall mean the percentage obtained by dividing the rentable square footage of the Leased Premises at the time of calculation by the rentable square footage of the Building
and the Other Buildings at the time of calculation. Such percentage is currently 29.07%. In the event that any portion of the Project is sold by Landlord, or if new improvements are constructed on the Project, or if the rentable square footage of
the Leased Premises, the Building, or the Other Buildings is otherwise changed (other than by mere re- measurement after the Initial Measurement of the

  
 5 

 Building D 
  

 

							
		  	Leased Premises and the Initial Measurement of the Building), Tenant’s Project Share shall be recalculated to equal the percentage described in the first sentence of this paragraph, so that the aggregate
Tenant’s Project Share of all tenant space in the Project shall equal 100% (calculated as if the Building and the Other Buildings were fully occupied). Landlord and Tenant agree that any mere re-measurement after the Initial Measurement of the
Leased Premises and the Initial Measurement of the Building (as opposed to an actual physical change) shall not result in a change in rentable square footage.
		
	Standard Interest Rate:	  	The term “Standard Interest Rate” shall mean the greater of (a) 6%, or (b) the sum of that rate quoted by Wells Fargo Bank, N.T. & S. A., from time to time as its prime rate, plus two percent
(2%), but in no event more than the maximum rate of interest not prohibited or made usurious.
		
	Default Interest Rate:	  	The term “Default Interest Rate” shall mean the Standard Interest Rate, plus five percent (5%), but in no event more than the maximum rate of interest not prohibited or made usurious.
		
	Base Monthly Rent:	  	The term “Base Monthly Rent” shall mean the following:

 
					
	Period	  	Base Monthly
Rent per
rentable
square foot
(rounded)*	  	Base
Monthly
Rent**
	Months 1-12	  	$2.90	  	$0.00
	Months 13-24	  	$2.90	  	$594,027.30
	Months 25-36	  	$2.97	  	$607,392.91
	Months 37-48	  	$3.03	  	$621,059.25
	Months 49-60	  	$3.10	  	$635,033.09
	Months 61-72	  	$3.17	  	$649,321.33
	Months 73-84	  	$3.24	  	$663,931.06
	Months 85-96	  	$3.31	  	$678,869.51
	Months 97-108	  	$3.39	  	$694,144.08
	Months 109-120	  	$3.47	  	$709,762.32
	Months 121-132	  	$3.54	  	$725,731.97

							
		
		  	 *These “per square foot” numbers are rounded. Actual numbers used for Base Monthly Rent are to equal rentable square
footage of 204,837 multiplied by $2.90 in months 13-24, and then increased by 2.25% each year thereafter.
 **Based upon the Leased Premises containing
204,837 rentable square feet of space, and subject to measurement as described in the “Leased Premises” definition above and adjustment.

		
	Permitted Use:	  	General office, administration, research and development, engineering laboratories, and other legal uses ancillary thereto, to the extent all such uses are in compliance with all Laws and Restrictions.
		
	Exhibits:	  	The term “Exhibits” and “Schedules” shall mean the Exhibits and Schedules of this Lease which are

  
 6 

 Building D 
  

 

			
			described as follows:
		
			Schedule 2.1 – Existing Title Encumbrances
		
			Schedule 2.2(a) – Approved Parking Area
		
			Exhibit A – Site Plan showing the Project and
			delineating the Building in which the Leased Premises
			are located
		
			Exhibit B – Floor Plan
		
			Exhibit C – Reserved
		
			Exhibit D – Work Letter
		
			Exhibit E – Lease Commencement Date Certificate
		
			Exhibit F – Reserved
		
			Exhibit G – Lump Sum Payment Amendment
		
			Exhibit H – Building Signage Exhibit
		
			Exhibit I – Subordination, Nondisturbance and
			Attornment Provisions
		
			Exhibit J – Form of Tenant Estoppel Certificate

 ARTICLE 2 

LEASED PREMISES, TERM AND POSSESSION 

2.1 Demise Of Leased Premises. Landlord hereby leases to Tenant and Tenant hereby leases from Landlord, for the Lease Term and upon the
terms and subject to the conditions of this Lease, that certain interior space described in Article 1 as the Leased Premises, reserving and excepting to Landlord the right to fifty percent (50%) of all assignment consideration and excess
rentals as provided in Article 7 below. Tenant’s lease of the Leased Premises, together with the appurtenant right to use the Common Areas as described in Paragraph 2.2 below, shall be conditioned upon and be subject to the continuing
compliance by Tenant with (i) all the terms and conditions of this Lease, (ii) all Laws and Restrictions governing the use or occupancy of the Leased Premises, the Property, and the Project, (iii) all easements and other matters now
of public record respecting the use of the Leased Premises, the Property, and the Project, shown on Schedule 2.1 attached hereto (the “Existing Title Encumbrances”), and (iv) all reasonable, non-discriminatory rules and
regulations from time to time established by Landlord. Notwithstanding any provision of this Lease to the contrary, Landlord hereby reserves to itself and its other tenants all rights of access, use and occupancy of the Building roof, and Tenant
shall have no right of access, use or occupancy of the Building roof except as provided for in Paragraph 4.14 below; provided, however, during the period, if any, that Tenant is leasing one hundred percent (100%) of all of the rentable
square footage in the Building, Tenant shall have the exclusive right to one hundred percent (100%) of the Available Rooftop Space (as defined in Paragraph 4.14 below). 

2.2 Common Areas, Fitness Center, Exclusive Use Area, and Bicycle Storage Area. 

(a) As an appurtenant right to Tenant’s right to the use and occupancy of the Leased Premises, Tenant shall have the right to use the
Common Areas in conjunction with its use of the Leased Premises solely for the purposes for which they were designed and intended and for no other purposes whatsoever. Tenant’s right to so use the Common Areas shall terminate concurrently with
any termination of this Lease. Further, Landlord shall have the right, from time to time, to reconfigure the Common Areas or modify the size of the Common Areas in connection with new construction on the Project or sales or subdivisions of portions
of the Project, provided that the following conditions (the “Required Conditions”) are satisfied: (i) Tenant’s access to the Leased Premises (including access through the lobby and the elevators of the Building) or
Tenant’s access to the number of parking spaces provided to Tenant hereunder, are not materially adversely affected thereby, (ii) Tenant’s parking allocation under Article 1 hereof is not reduced thereby, (iii) a minimum of 3.3
parking spaces for each 1,000 net rentable square feet of Leased Premises continue to be located within the area depicted by a curved dotted line on Schedule 2.2(a) attached to this Lease, (iv) Tenant shall have access to: (A) the
Fitness Center contemplated by Paragraph 2.2(b) below, (B) if applicable, the Exclusive Use Areas described in Paragraph 2.2(c) below, and (C) a comparable and similarly located bicycle storage area as contemplated by Paragraph 2.2(d)
below, and (v) the exterior Common Area in the proximity of the Building continues to be consistent in quality and design with the existing finished exterior Common Area at the Project. 

  
 7 

 Building D 
  

(b) Additionally, on the Lease Commencement Date, Tenant shall have the right to use the Fitness Center solely for the purposes for which they
were designed and intended and for no other purposes whatsoever. Tenant’s right to use the Fitness Center shall be subject to such reasonable rules and regulations as Landlord or its vendors may issue from time to time, provided that in no
event shall Landlord charge Tenant or any Tenant Party a fee for the use of the Fitness Center. Tenant’s right to use the Fitness Center shall terminate concurrently with any termination of this Lease. Landlord retains the right to relocate the
Fitness Center to another location on the Project (and change the size of the Fitness Center if it is relocated), so long as the Required Conditions are satisfied, the size is not reduced by more than ten percent (10%) and, in the event of any
such change, the quality and nature of the facilities provided in the Fitness Center at such new location shall not be materially diminished. If Landlord exercises this option, the rentable area of the Leased Premises, Base Monthly Rent, and
Tenant’s Building Share and Tenant’s Property Share shall be adjusted accordingly, based on the Measurement Method. 
 (c) So long
as Tenant is leasing at least five (5) full floors of the Building and one (1) full floor of Building C, Tenant will have exclusive access to the areas in the general locations denoted on the Site Plan as “Exclusive Use Areas”
(and defined herein as the “Exclusive Use Common Areas”) for purposes of developing its own exterior eating area and two (2) sport courts. 

(d) In addition, on or prior to the Lease Commencement Date, Landlord, at its sole cost and expense, will install a bicycle storage area to
store bicycles used by Tenant’s employees located in the general area delineated in blue on the Site Plan as “Building D Bike Lockers.” No rent shall be required for the bicycle storage during the Lease Term (as the same may be
extended pursuant to Article 15 below). If Tenant desires additional bicycle storage lockers, Tenant shall have the right to install the same at its sole cost and expense in a location to be agreed upon by Landlord and Tenant in their reasonable
discretion. If such additional bicycle storage lockers are located on any parking areas on the Project, then such lost parking spaces shall be counted towards satisfying Tenant’s parking allocation under Article 1 hereof. 

2.3 Lease Commencement Date And Lease Term. Subject to Paragraph 2.4 below, the term of this Lease shall begin, and the Lease
Commencement Date shall be deemed to have occurred, on the later of (a) March 1, 2017, and (b) ninety (90) days after Landlord has delivered the Leased Premises to Tenant in the Required Delivery Condition as defined in Paragraph
2.4(a) below subject to extension for Landlord Delays (as defined in Paragraph 7of the Work Letter) and for up to twenty (20) days of Unavoidable Tenant Improvement Delays, as defined in Paragraph 8 of the Work Letter (such later date, the
“Lease Commencement Date”). The term of this Lease shall in all events end on the Lease Expiration Date (as set forth in Article 1, as the same may be extended pursuant to Article 15 below); provided, however, that if the
Lease Expiration Date of this Lease or the Building C Lease shall not be simultaneous because of any differences in the dates on which Landlord delivers this Leased Premises and the Building C Leased Premises to Tenant, then, at Tenant’s
option, which option must be exercised by written notice thereof to Landlord delivered no later than the Lease Commencement Date of the later of such leases to commence, the Lease Expiration Date of this Lease or the Building C Lease, as relevant,
shall be extended such that the Lease Expiration Date of both this Lease and the Building C Lease shall be upon the later Lease Expiration Date of this Lease or the Building C Lease. The Lease Term shall be that period of time commencing on the
Lease Commencement Date and ending on the Lease Expiration Date (the “Lease Term”). Promptly after the Lease Commencement Date has been determined, Landlord and Tenant shall execute and deliver a Lease Commencement Date Certificate
in the form of Exhibit E attached hereto. 
 2.4 Delivery Of Possession. 

(a) Landlord shall construct the Building pursuant to Paragraph 1 of the Work Letter and deliver the Leased Premises to Tenant on the date (the
“Delivery Date”) that the Required Delivery Condition has been achieved. As used herein, the term “Required Delivery Condition” means (i) the steel structure has been constructed, (ii) the concrete slab
and decks have been poured, (iii) the roof of the Building has been installed, and (iv) the exterior skin of the Building is water tight. If the Delivery Date has not occurred by December 1, 2016 due solely to delays caused by
Landlord, and provided that Tenant either (A) has not made the Early Access Election described in Paragraph 2.4(b) below, or (B) is using Devcon as its Tenant Improvement Contractor (as defined in the Work Letter), then Tenant shall be
entitled to a credit against Base Monthly Rent (the “Rent Credit”) equal to $13,500 per day for each day after December 1, 2016 (subject to a thirty (30) day grace period) until the Delivery Date occurs (excluding any
periods of delay caused by Tenant Delay (as defined in the Work Letter)), but only to the extent such delay in the Delivery Date causes Tenant’s completion of the Tenant Improvements to be delayed past March 1, 2017. 

  
 8 

 Building D 
  

(b) Subject to obtaining Landlord’s prior written consent, which shall not be unreasonably withheld, Tenant may elect (the “Early
Access Election”) to enter the Leased Premises, prior to the Delivery Date, commencing on the Early Access Date (as defined below) for the sole purpose of constructing tenant improvements, provided that Tenant does not interfere with
Landlord’s construction of the base Building and complies with all other provisions of this Lease (other than payment of Base Monthly Rent and Additional Rent). The “Early Access Date” shall be the date on which
(i) the steel structure has been constructed, and (ii) the concrete slab and decks have been poured. Landlord currently estimates that the Early Access Date will occur during the month of September, 2016. 

(c) In addition, on or prior to March 1, 2017 (as such date may be extended due to Tenant Delays and a maximum of (30) days of such
Force Majeure delays), Landlord shall deliver possession of the Leased Premises “Substantially Complete,” defined herein to mean (i) the Building shall have been substantially completed in accordance with the Final Base
Building Plans (as defined in Paragraph 1 of the Work Letter) therefor and the City of Santa Clara shall have signed off on the building permit for the Building, but for minor punch list items, (ii) all Building systems and subsystems described
in Exhibit A-1 to the Work Letter, the structural elements of the Leased Premises and the Building, and the foundation of the Building, are in good working order and repair, (iii) all improvements needed for the Building (excluding the Leased
Premises) and the Common Areas to be in compliance with the Santa Clara Building Code and the Americans With Disabilities Act have been completed, (iv) the number of parking spaces required by this Lease shall have been completed, (v) the
Fitness Center shall have been completed and Tenant and the Tenant Parties shall have access thereto and use thereof (which Tenant hereby acknowledges has been completed), (vi) the elevators, stairwells, shared restrooms, ground floor lobby,
and associated mechanical, engineering, and plumbing shall have been substantially completed, and (vii) all scaffolding shall have been removed from the Building. Substantial Completion of the Building and Warm Shell Components (as defined in
Paragraph 1 of the Work Letter) shall be deemed to have occurred when the City has signed off on the final building permit. 
 (d) If by four
(4) months after the date set forth in Paragraph 2.4(c) above (as such date may be extended any Tenant Delays and up to thirty (30) days of Force Majeure), Landlord shall not have delivered possession of the Leased Premises Substantially
Complete, Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) business days of such date (as extended if extended). 

(e) Any Tenant Delay during either the period after the Delivery Date or after the Early Access Date, as applicable, shall serve to extend the
December 1, 2016 date set forth in Paragraph 2.4(a) above and the March 1, 2017 date set forth in Paragraph 2.4(c) above on a day-for-day basis. 

(f) Notwithstanding any other provision of this Lease or the Work Letter to the contrary, Tenant shall be responsible for payment of all
utility charges reasonably attributable to the construction of the Tenant Improvements (and not the Landlord Work) relating to the period from the Delivery Date through the Lease Commencement Date, after which Paragraph 3.2 below shall govern. 

2.5 Performance Of Tenant Improvement Work; Acceptance Of Possession. Tenant shall, pursuant to the Work Letter, perform the work and
make the installations in the Leased Premises substantially as set forth in the Work Letter (such work and installations hereinafter referred to as the “Tenant Improvements”). Subject to the terms of Paragraph 2.8 below, it is
agreed that by accepting possession of the Substantially Complete Leased Premises, Tenant agrees that it will have accepted the same and acknowledged that the Leased Premises are in the condition called for under this Lease (including the Work
Letter). 
 2.6 Surrender Of Possession. Immediately prior to the expiration or upon the sooner termination of this Lease, Tenant
shall remove all of Tenant’s signs from the exterior of the Building and shall remove all of Tenant’s equipment (including telecommunications wiring and cabling), trade fixtures, furniture, supplies, wall decorations and other personal
property from within the Leased Premises, the Building and the Common Areas, and shall vacate and surrender the Leased Premises, the Building, the Common Areas, the Property, and the Project to Landlord in the same condition, broom clean, as existed
at the Lease Commencement Date, reasonable wear and tear and damage caused by Landlord or Landlord’s employees, agents, contractors, or subcontractors (collectively with Landlord, the “Landlord Parties”) and casualty not caused
by Tenant or Tenant Parties, excepted. Tenant shall repair all damage to the Leased Premises, the exterior of the Building and the Common Areas caused by Tenant’s removal of Tenant’s property. Tenant shall patch and refinish, to
Landlord’s reasonable satisfaction, all penetrations made by Tenant or its employees to the floor, walls or ceiling of the Leased Premises, whether such penetrations were made with Landlord’s approval or not. Tenant shall repair or replace
all stained or damaged ceiling tiles, wall coverings and floor coverings to the reasonable satisfaction of Landlord. Subject to the terms of Paragraph 9.3 below, Tenant shall repair all damage caused by Tenant to the exterior surface of the Building
and the Exclusive Use Common Areas and, where necessary, replace or resurface same. Additionally, to the extent that Landlord shall have notified or is deemed to have notified Tenant in writing at the time the applicable improvements were consented
to, that it desired 

  
 9 

 Building D 
  

to have certain Non-Standard Office Improvements made by or at the request of Tenant removed at the expiration or sooner termination of this Lease, Tenant shall, upon the expiration or sooner
termination of this Lease: (A) remove such Non-Standard Office Improvements constructed or installed by Landlord or Tenant (including any backup generator or other mechanical equipment), but only if they had been identified as Non-Standard
Office Improvements by Landlord at the time consented to pursuant to Paragraph 6.1 below or the Work Letter, as applicable, and (B) repair all damage caused by such removal. If the Leased Premises, the Building, and the Exclusive Use Common
Areas are not surrendered to Landlord in the condition required by this paragraph at the expiration or sooner termination of this Lease, Landlord may, at Tenant’s expense, so remove Tenant’s signs, property and/or improvements not so
removed and make such repairs and replacements not so made or hire, at Tenant’s expense, independent contractors to perform such work. Tenant shall be liable to Landlord for all costs incurred by Landlord in returning the Leased Premises, the
Building and the Exclusive Use Common Areas to the required condition, together with interest on all costs so incurred from the date paid by Landlord at the Default Interest Rate until paid. Tenant shall pay to Landlord the amount of all costs so
incurred plus such interest thereon, within thirty (30) days of Landlord’s billing Tenant for same. Tenant shall not be required to remove its initial Tenant Improvements constructed pursuant to and in accordance with the Work Letter,
except to the extent they constitute “Non-Standard Office Improvements,” defined herein to mean alterations, modifications, and improvements that (i) affect the Building façade or structure, (ii) are other than
typical leasehold improvements for office tenants in the Building or in buildings similar to the Building in the area in which the Property is located, or (iii) in Landlord’s reasonable judgment would materially increase Landlord’s
cost of preparing the Leased Premises for another tenant (such as, without limitation, interior staircases). As further illustration of items that may or may not be considered Non-Standard Office Improvements: (1) Tenant improvements of a type
or quantity that would not be installed by or for a typical tenant using space for general office or research and development purposes, such as internal stairwells or high density mobile filing systems, auditoriums, movie theaters or film projection
rooms, private restrooms, data center rooms, swimming pools, basketball courts, laboratories and, supplemental HVAC units or ducting would be considered Non-Standard Office Improvements; and (2) “open ceilings”, kitchens, lunch rooms,
cafés, break rooms, small, non-specialized server rooms, and expanded restroom areas built by Tenant would be considered Non-Standard Office Improvements. 

2.7 Accessibility. In accordance with California Civil Code section 1938, Landlord hereby informs Tenant that as of the Effective Date
of this Lease, neither the Leased Premises nor the Building have been inspected by a Certified Access Specialist (as defined in California Civil Code section 55.52(3)). 

2.8 Condition Upon Substantial Completion. Landlord hereby warrants that the Warm Shell Components (as defined in the Work Letter) and
the Common Areas supporting the Building, consisting of (i) a minimum of 3.3 parking spaces for each 1,000 net rentable square feet of Leased Premises located within the area depicted by a curved dotted line on Schedule 2.2(a) attached
to this Lease, (ii) such sidewalks or paths as are necessary to allow Tenant access from the parking areas to the Building, and (iii) the landscaping in front of the Building (defined for purposes of this Lease as the “Building
Specific Common Areas”) shall be in good working condition as of the date of Substantial Completion thereof (the “Substantial Completion Date”). In the event that Tenant believes, and Tenant notifies Landlord in writing
within twelve (12) months after the Substantial Completion Date, that the Warm Shell Components or Building Specific Common Areas were not in good working condition and repair on the Substantial Completion Date, then unless Landlord disagrees,
Landlord shall, at Landlord’s sole cost and expense (which shall not be deemed a Property Maintenance Cost), repair or replace any failed or inoperable portion of such Warm Shell Components or Building Specific Common Areas, as applicable
(“Landlord’s Warranty”), provided that the need to repair or replace was not caused by the misuse, misconduct, damage, destruction, acts, omissions, and/or negligence (collectively, “Tenant Damage”) of Tenant
or any Tenant Parties, or by any modifications, alterations, or improvements (including the Tenant Improvements) constructed by or on behalf of Tenant. Landlord’s Warranty shall not be deemed to require Landlord to replace any portion of any
Warm Shell Components or Building Specific Common Areas, as applicable, as opposed to repair such portion of such Warm Shell Components or Building Specific Common Areas, as applicable, unless prudent commercial property management practices dictate
replacement rather than repair of the item in question. To the extent repairs which Landlord is required to make pursuant to this Paragraph 2.8 are necessitated in part by Tenant Damage and not fully covered by Landlord’s insurance, then Tenant
shall reimburse Landlord for an equitable proportion of the cost of such repair. If it is determined that the Warm Shell Components or Building Specific Common Areas (or any portion thereof) were not in good working condition and repair as of the
Substantial Completion Date, Landlord shall not be liable to Tenant for any damages, but Landlord, at no cost to Tenant, shall promptly commence such work or take such other action as may be necessary to place the same in good working condition and
repair, and shall thereafter diligently pursue the same to completion; and Landlord shall repair any damage to the Tenant Improvements arising in connection with Landlord’s work. Tenant’s failure to give such written notice to Landlord
within twelve (12) months after the Substantial Completion Date shall constitute a conclusive presumption that the Warm Shell Components (or Building Specific Common Areas, as applicable) are in good working condition and repair, and any required
correction after that date shall be performed by the party 

  
 10 

 Building D 
  

responsible for such repair pursuant to the terms of this Lease; provided, however, the foregoing shall not constitute a waiver by Tenant or a release of
Landlord with respect to Landlord’s obligations under this Lease relating to the construction of the Building and the Project. In the event that Tenant notifies Landlord in writing within twelve (12) months after the Substantial Completion
Date, that the Warm Shell Components or Building Specific Common Areas were not in good working condition and repair on the Substantial Completion Date, and Landlord disagrees, then Landlord and Tenant shall meet and confer in good faith to try to
reach agreement within thirty (30) days, failing which the matter shall be referred to arbitration before a single arbitrator at JAMS in San Francisco. 

ARTICLE 3 
 RENT 

3.1 Base Monthly Rent. 

(a) Commencing on the Lease Commencement Date (as determined pursuant to Paragraph 2.3 above) and continuing throughout the Lease Term, Tenant
shall pay to Landlord, without prior demand therefor, in advance on the first day of each calendar month, cash or other immediately available good funds in the amount set forth as Base Monthly Rent in Article 1. 

(b) Base Monthly Rent is not payable during the first twelve (12) months of the Lease Term (the “Rent Abatement
Period”). Notwithstanding anything to the contrary contained in this Lease, Landlord shall have the option (the “Lump Sum Payment Option”) to require Tenant to pay Base Monthly Rent for so much of the Rent Abatement
Period as remains following Landlord’s notice as hereinafter provided at the rate of $594,027.30 per month, beginning on the date (the “Base Monthly Rent Start Date”) set forth in the Lump Sum Payment Option Notice (defined
below), which shall in no event be a date prior to payment to Tenant of the Abated Rent Lump Sum Payment. To exercise the Lump Sum Payment Option, Landlord must (i) provide written notice to Tenant of such exercise (the “Lump Sum
Payment Option Notice”) and (ii) pay to Tenant the Base Monthly Rent that would be payable for the remaining Rent Abatement Period (the “Abated Rent Lump Sum Payment”). If Landlord elects its Lump Sum Payment Option,
the Abated Rent Lump Sum Payment shall be made, at Landlord’s election (a) within thirty (30) days of Tenant’s receipt of the Lump Sum Payment Option Notice, or (b) on the closing date of any financing or sale of the
Building by Landlord (the date of such payment is hereinafter referred to as the “Lump Sum Payment Date”). If Landlord fails to pay the Abated Rent Lump Sum Payment by the Lump Sum Payment Date or the financing or sale transaction
for the Building, if applicable, expires or is terminated or deemed null and void for any reason, Landlord’s exercise of the Lump Sum Payment Option shall be deemed null and void and of no further force or effect and the Abated Rent Lump Sum
Payment, if theretofore paid by Landlord to Tenant, shall promptly be returned by Tenant to Landlord. If Landlord’s Lump Sum Payment Notice is effective on a day other than the first day of a calendar month and Landlord has then paid the Abated
Rent Lump Sum Payment, then Tenant shall pay any Base Monthly Rent payable hereunder for the period from Landlord’s Lump Sum Payment Option Notice through the last day of the calendar month, with the next installment of Base Monthly Rent due
for the following calendar month. 
 (c) If Landlord exercises its Lump Sum Payment Option in accordance with the above paragraph, Landlord
shall prepare an amendment in the form of Exhibit G attached hereto (the “Lump Sum Payment Amendment”) that documents the effect of Landlord’s exercise of the Lump Sum Payment Option and sets forth a revised rent
schedule reflecting Tenant’s payment of the Base Monthly Rent for the remaining Rent Abatement Period following the Lump Sum Payment Option Notice. A copy of the Lump Sum Payment Amendment shall be sent to Tenant and Tenant shall execute and
return the Lump Sum Payment Amendment to Landlord within ten (10) business days thereafter, but Landlord’s otherwise valid exercise of the Lump Sum Payment Option shall be fully effective whether or not the Lump Sum Payment Amendment is
executed. 
 3.2 Additional Rent. Commencing on the Lease Commencement Date (as determined pursuant to Paragraph 2.3 above) and
continuing throughout the Lease Term, in addition to the Base Monthly Rent and to the extent not required by Landlord to be contracted for and paid directly by Tenant, Tenant shall pay to Landlord as additional rent (the “Additional
Rent”), cash or other immediately available good funds in the following amounts: 
 (a) An amount equal to all Property Operating
Expenses (as defined in Article 13) incurred or to be incurred by Landlord. Landlord shall deliver to Tenant Landlord’s reasonable estimate of any given expense (such as Landlord’s Insurance Costs or Real Property Taxes), or group of
expenses, which it anticipates will be paid or incurred for the ensuing calendar or fiscal year, as Landlord may determine, and Tenant shall pay to Landlord an amount equal to Tenant’s Building Share or Tenant’s Project Share, as
applicable, of the estimated amount of such expenses for such year in equal monthly installments during such year with the installments of Base Monthly Rent. Landlord reserves the right to revise such estimate from time to time but not more than
once during the applicable year and, in any event shall provide Tenant with at least one (1) month advance notice of such adjusted estimates taking effect. 

  
 11 

 Building D 
  

(b) Landlord’s share of the consideration received by Tenant upon certain assignments and sublettings as required by Article 7. 

(c) Any legal fees and costs that Tenant is obligated to pay or reimburse to Landlord pursuant to Article 13; and 

(d) Any other charges or reimbursements due Landlord from Tenant pursuant to the terms of this Lease. 

Notwithstanding the foregoing, at any time that Tenant leases all of the rentable square footage in the Building, Landlord may elect by written notice to
Tenant to have Tenant pay Real Property Taxes or any portion thereof directly to the applicable taxing authority, in which case Tenant shall make such payments and deliver satisfactory evidence of payment to Landlord no later than ten (10) days
before such Real Property Taxes become delinquent. In the event Tenant is responsible to pay taxes directly, Landlord shall have no obligation to make such payments, whether or not Landlord receives evidence of payment from Tenant, and Tenant shall
in all cases be responsible for any fines, penalties, interest and damages for late payment. 
 3.3 Year-End Adjustments. Landlord
shall furnish to Tenant within four months following the end of the applicable calendar or fiscal year, as the case may be, a statement setting forth (i) the amount of such expenses paid or incurred during the just ended calendar or fiscal
year, as appropriate, and (ii) the amount that Tenant has paid to Landlord for credit against such expenses for such period. If Tenant shall have paid more than its obligation for such expenses for the stated period, Landlord shall, at its
election, either (i) credit the amount of such overpayment toward the next ensuing payment or payments of Additional Rent that would otherwise be due or (ii) refund in cash to Tenant the amount of such overpayment within thirty
(30) days after discovery of such surplus; provided, however, that if this Lease shall have terminated, Landlord shall be deemed to have chosen option (ii) above. If such year-end statement shall show that Tenant did not pay its obligation
for such expenses in full, then Tenant shall pay to Landlord the amount of such underpayment within thirty (30) days from Landlord’s billing of same to Tenant. Tenant may, at Tenant’s sole cost and expense, cause an audit of
Landlord’s books and records to determine the accuracy of Landlord’s billings for Property Operating Expenses under this Lease, provided Tenant completes (and delivers to Landlord the written results of) such audit within two hundred
seventy (270) days after Tenant’s receipt of the year-end statement described above setting forth the annual reconciliation of the Property Operating Expenses, and provided further that the person or entity performing such audit is not
compensated on any type of contingent basis. If such audit reveals that the actual Property Operating Expenses for any given year were less than the amount that Tenant paid for Property Operating Expenses for any such year, then unless Landlord
contests such audit results as provided below, Landlord shall credit the excess to Tenant’s next payment of Additional Rent. If such audit reveals that the actual Property Operating Expenses for any given year were more than the amount that
Tenant paid for Property Operating Expenses for any such year, Tenant shall pay such amount to Landlord within thirty (30) days after completion of the audit. Landlord shall have the right to contest the results of Tenant’s audit and
thereafter promptly have an audit performed (“Landlord’s Audit”) by a certified public accounting firm acceptable to Landlord and Tenant in their reasonable discretion. In such case, the results of Landlord’s Audit shall
be binding and conclusive on Landlord and Tenant, and any resulting overpayment or underpayment shall be handled as provided above. If Landlord’s Audit, or Tenant’s audit in the event Landlord does not elect to have Landlord’s Audit
performed, confirms that Tenant was overcharged by more than five percent (5%), then Landlord shall pay the cost of Tenant’s audit (up to a maximum of $7,500) and Landlord’s Audit. If Tenant’s audit confirms that Tenant was not
overcharged, then Tenant shall pay the cost of Landlord’s Audit (up to a maximum of $7,500) and Tenant’s audit. In all other cases, each party shall pay for its own audit. The provisions of this Paragraph shall survive the expiration or
sooner termination of this Lease. 
 3.4 Late Charge, And Interest On Rent In Default. Tenant acknowledges that the late payment by
Tenant of any monthly installment of Base Monthly Rent or any Additional Rent will cause Landlord to incur certain costs and expenses not contemplated under this Lease, the exact amounts of which are extremely difficult or impractical to fix. Such
costs and expenses will include without limitation, administration and collection costs and processing and accounting expenses. Therefore, if any installment of Base Monthly Rent is not received by Landlord from Tenant within five (5) calendar
days after the same becomes due, Tenant shall immediately pay to Landlord a late charge in an amount equal to the amount set forth in Article 1 as the “Late Charge Amount,” and if any Additional Rent is not received by Landlord when
the same becomes due, Tenant shall immediately pay to Landlord a late charge in an amount equal to 5% of the Additional Rent not so paid; provided, however, that once but only once in any twelve (12) month period during the Lease Term, Tenant
shall be entitled to written notice of non-receipt of Base Monthly Rent or Additional Rent from Landlord, and Tenant shall not be liable for any Late Charge Amount or other late charge hereunder with respect thereto if such installment

  
 12 

 Building D 
  

of Base Monthly Rent or Additional Rent is received by Landlord within three (3) business days after Tenant’s receipt of such written notice from Landlord. Landlord and Tenant agree
that this late charge represents a reasonable estimate of such costs and expenses and is fair compensation to Landlord for the anticipated loss Landlord would suffer by reason of Tenant’s failure to make timely payment. In no event shall this
provision for a late charge be deemed to grant to Tenant a grace period or extension of time within which to pay any rental installment or prevent Landlord from exercising any right or remedy available to Landlord upon Tenant’s failure to pay
each rental installment due under this Lease when due, including the right to terminate this Lease. If any rent remains delinquent for a period in excess of five (5) calendar days, then, in addition to such late charge, Tenant shall pay to
Landlord interest on any rent that is not so paid from said fifth (5th) day at the Default Interest Rate until paid. 
 3.5 Payment
Of Rent. Except as specifically provided otherwise in this Lease, all rent shall be paid in lawful money of the United States, without any abatement, reduction or offset for any reason whatsoever, to Landlord at such address as Landlord may
designate from time to time at least thirty (30) days in advance of the date the next payment of rent is due. Tenant’s obligation to pay Base Monthly Rent and all Additional Rent shall be appropriately prorated at the commencement and
expiration of the Lease Term. The failure by Tenant to pay any Additional Rent as required pursuant to this Lease when due shall be treated the same as a failure by Tenant to pay Base Monthly Rent when due, and Landlord shall have the same rights
and remedies against Tenant as Landlord would have had Tenant failed to pay the Base Monthly Rent when due. 
 ARTICLE 4 

USE OF LEASED PREMISES AND COMMON AREA 

4.1 Permitted Use. Tenant shall be entitled to use the Leased Premises on a 24/7/365 basis solely for the Permitted Use as set forth in
Article 1 and for no other purpose whatsoever. Tenant shall have the right to vacate the Leased Premises at any time during the Term of this Lease, provided Tenant maintains the Leased Premises in the same condition as if fully occupied and as
otherwise required by the terms of this Lease. Tenant shall have the right to use the Common Areas in conjunction with its Permitted Use of the Leased Premises solely for the purposes for which they were designed and intended and for no other
purposes whatsoever. 
 4.2 General Limitations On Use. Tenant shall not do or permit anything to be done in or about the Leased
Premises, the Building, the Common Areas, the Property, or the Project which does or could (i) jeopardize the structural integrity of the Building or (ii) cause damage to any part of the Leased Premises, the Building, the Common Areas, the
Property, or the Project. Tenant shall not operate any equipment within the Leased Premises which does or could (A) injure, vibrate or shake the Leased Premises or the Building, (B) damage, overload or impair the efficient operation of any
electrical, plumbing, and HVAC systems within or servicing the Leased Premises or the Building, or (C) damage or impair the efficient operation of the sprinkler system (if any) within or servicing the Leased Premises or the Building. Tenant
shall not install any equipment or antennas on or make any penetrations of the exterior walls or roof of the Building, except to the extent specifically set forth in the Tenant Improvement Working Drawings approved by Landlord pursuant to Paragraph
2 of the Work Letter or as otherwise provided in Paragraph 4.14 below. Tenant shall not affix any equipment to or make any penetrations or cuts in the floor, ceiling, walls or roof of the Leased Premises except to the extent specifically set forth
in the Tenant Improvement Working Drawings approved by Landlord pursuant to Paragraph 2 of the Work Letter or any alterations to the Leased Premises approved by Landlord pursuant to Paragraph 6.1 below. Tenant shall not place any loads upon the
floors, walls, ceiling or roof systems which could endanger the structural integrity of the Building or damage its floors, foundations or supporting structural components. Tenant shall not place any explosive, flammable or harmful fluids or other
waste materials in the drainage systems of the Leased Premises, the Building, the Common Areas, the Property, or the Project. Tenant shall not drain or discharge any fluids in the landscaped areas or across the paved areas of the Property or the
Project. Tenant shall not use any of the Common Areas for the storage of its materials, supplies, inventory or equipment and all such materials, supplies, inventory or equipment shall at all times be stored within the Leased Premises. Tenant shall
not commit nor permit to be committed by any of its employees, agents, vendors, invitees, guests, permittees, assignees, sublessees, contractors, or subcontractors (the “Tenant Parties”), any physical waste in or about the Leased
Premises, the Building, the Common Areas, the Property, or the Project. 
 4.3 Noise And Emissions. All noise generated by Tenant in
its use of the Leased Premises shall be confined or muffled so that it does not interfere with the businesses of or annoy the occupants and/or users of adjacent properties. All dust, fumes, odors and other emissions generated by Tenant’s use of
the Leased Premises shall be sufficiently dissipated in accordance with sound environmental practice and exhausted from the Leased Premises in such a manner so as not to interfere with the businesses of or annoy the occupants and/or users of
adjacent properties, or cause any damage to the Leased Premises, the Building, the Common Areas, the Property, or the Project or any component part thereof or the property of adjacent property owners. 

  
 13 

 Building D 
  

4.4 Trash Disposal. Landlord shall provide trash bins or other adequate garbage disposal facilities within the trash enclosure areas
provided or permitted by Landlord outside the Leased Premises sufficient for the interim disposal of all of its trash, garbage and waste. All such trash, garbage and waste temporarily stored in such areas by Tenant or any of the Tenant Parties shall
be stored in such a manner so that it is not visible from outside of such areas. Landlord shall cause such trash, garbage and waste to be regularly removed from the trash bins/garbage disposal facilities and the Property. Subject to the foregoing
removal obligation of Landlord, Tenant shall keep the interior of the Leased Premises in a clean, safe and neat condition and shall keep the Common Areas free and clear of all of Tenant’s trash, garbage, waste and/or boxes, pallets and
containers containing same at all times. 
 4.5 Parking. Tenant shall not, at any time, park or permit to be parked any recreational
vehicles, inoperative vehicles or equipment in the Common Areas or on any portion of the Project. Tenant agrees to assume responsibility for compliance by its employees and invitees with the parking provisions contained herein. If Tenant or its
employees park any vehicle within the Property or the Project in violation of these provisions, then Landlord may, upon prior written notice to Tenant giving Tenant two (2) days (or any applicable statutory notice period, if longer than two
(2) days) to remove such vehicle(s), cause the same to be removed at Tenant’s expense. Tenant agrees to assume responsibility for compliance by the Tenant Parties with the parking provisions contained herein. Landlord reserves the right to
grant easements and access rights to others for use of the parking areas on the Property and/or Project, provided that the Required Conditions are satisfied. Tenant shall have the right to install electric vehicle charging stations (“ECV
Stations”) on the Property in a location acceptable to Landlord in its reasonable discretion, all at Tenant’s sole cost, including but not limited to the cost of running conduit; provided, however, that Tenant may (within sixty
(60) days after the Effective Date of this Lease, if at all) request Landlord to provide conduit to up to such number of Tenant’s Exclusive Parking Spaces as Tenant shall request, from the Building electrical room, in which case Landlord
shall provide such conduit at Landlord’s sole cost. Further, Tenant may (within sixty (60) days after the Effective Date of this Lease, if at all) request Landlord to provide conduit to up to such number of Tenant’s Additional
Exclusive Parking Spaces as Tenant shall request, from the Building electrical room, in which case Landlord shall provide such conduit at Tenant’s sole cost (which may be paid out of the Tenant Improvement Allowance). Finally, if requested by
Tenant, Landlord will agree to establish a valet parking system for the occupants of the Leased Premises, and all costs relating thereto would be payable by Tenant as Additional Rent; provided, however, that if the sixth floor of the Building
is leased to a tenant other than Tenant, and such tenant desires to utilize the valet parking system, then Tenant’s Building Share of the cost of the valet parking system would be passed through to Tenant as a Property Maintenance Cost.
Landlord agrees not to grant more parking to the tenants of the Project than is available on the Project. 
 4.6 Signs. Tenant shall
not place or install on or within any portion of the Leased Premises, the exterior of the Building, the Common Areas, the Property, or the Project any sign, advertisement, banner, placard, or picture which is visible from the exterior of the Leased
Premises, except as expressly allowed pursuant to this Paragraph 4.6. Subject to the other terms and conditions of this Paragraph 4.6, Tenant, at Tenant’s sole cost and expense, shall: (i) have the right to install its name on the lobby
directory sign, (ii) be entitled to place its name on the Building top in two locations generally as depicted on Exhibit H, and (iii) be entitled to place its name on the Project entry vertical sign generally as depicted on
Exhibit H, in all cases in accordance with Landlord’s Building signage program and to the extent approved by the City of Santa Clara. Notwithstanding the foregoing, in the event that Tenant exercises any extension option pursuant to
Article 15 below for less than five (5) full floors in the Building, then the Building-top sign denoted on Exhibit H as “Sign Subject to Relinquishment” shall be removed by Tenant and the Building façade beneath such
sign shall be returned to its original condition, all at Tenant’s sole cost and expense. The size, location, and configuration of all signage shall be subject to Landlord’s building standards and its prior written approval, which shall not
be unreasonably withheld, and shall be governed by and subject to the rules, regulations and permit requirements of the City of Santa Clara. All of the foregoing rights set forth in this paragraph shall be personal to Aruba Networks, Inc., or a
sublessee of more than 50% of the initial Leased Premises, or an assignee, and no other party shall have any such right. Except as provided above, Tenant shall not place or install on or within any portion of the Leased Premises, the exterior of the
Building, the Common Areas, the Property, or the Project any business identification sign which is visible from the exterior of the Leased Premises until Landlord shall have approved in writing and in its sole discretion the location, size, content,
design, method of attachment and material to be used in the making of such sign; provided, however, that so long as such signs are normal and customary business directional or identification signs within the Building, Tenant shall not
be required to obtain Landlord’s approval. Any sign, once approved by Landlord, shall be installed at Tenant’s sole cost and expense and only in strict compliance with Landlord’s approval and any applicable Laws and Restrictions,
using a person approved by Landlord to install same. Landlord may remove any signs (which have not been approved in writing by Landlord), advertisements, banners, placards or pictures so placed by Tenant on or within the Leased Premises, the
exterior of the Building, the Common Areas, the Property, or the Project and charge to Tenant the cost of such removal, together with any costs incurred by Landlord to repair any damage caused thereby, including any cost incurred to restore the
surface (upon which such sign was so affixed) to its original condition. Tenant shall remove 

  
 14 

 Building D 
  

all of Tenant’s signs, repair any damage caused thereby, and restore the surface upon which the sign was affixed to its original condition, all to
Landlord’s reasonable satisfaction, upon the termination of this Lease. Notwithstanding the signage rights granted to Tenant pursuant to this Paragraph 4.6, Landlord reserves and retains the right to place Landlord’s name and/or ownership
affiliation in or on the Leased Premises, the Building, the Common Areas, the Property, or the Project, or on any of the signs located thereon, as determined in Landlord’s sole discretion. 

4.7 Compliance With Laws And Restrictions. Subject to Paragraph 6.3 below, Tenant shall abide by and shall promptly observe and comply
with, at its sole cost and expense, all Laws and Restrictions respecting the use and occupancy of the Leased Premises, the Building, the Common Areas, the Property, or the Project including, without limitation, Title 24, building codes, the
Americans with Disabilities Act and the rules and regulations promulgated thereunder, and all Laws governing the use and/or disposal of hazardous materials, and shall defend with competent counsel, indemnify and hold Landlord harmless from any
claims, damages or liability resulting from Tenant’s failure to so abide, observe, or comply. Tenant’s obligations hereunder shall survive the expiration or sooner termination of this Lease. 

4.8 Compliance With Insurance Requirements. With respect to any insurance policies required or permitted to be carried by Landlord in
accordance with the provisions of this Lease, Tenant shall not conduct nor permit any other person to conduct any activities nor keep, store or use (or allow any other person to keep, store or use) any item or thing within the Leased Premises, the
Building, the Common Areas, the Property, or the Project which (i) is prohibited under the terms of any such policies, (ii) could result in the termination of the coverage afforded under any of such policies, (iii) could give to the
insurance carrier the right to cancel any of such policies, or (iv) could cause an increase in the rates (over standard rates) charged for the coverage afforded under any of such policies. Tenant shall comply with all requirements of any
insurance company, insurance underwriter, or Board of Fire Underwriters which are necessary to maintain, at standard rates, the insurance coverages carried by either Landlord or Tenant pursuant to this Lease. 

4.9 Landlord’s Right To Enter. Landlord and its agents shall have the right to enter the Leased Premises during normal business
hours after giving Tenant reasonable notice (which shall be prior written notice except in the event of a circumstance which Landlord in good faith believes to be an emergency) and subject to Tenant’s reasonable security measures for the
purpose of (i) inspecting the same; (ii) showing the Leased Premises to prospective purchasers, mortgagees or, during the last nine (9) months of the Lease Term or during any period that Tenant is in monetary or material non-monetary
default beyond the applicable cure period, if any, expressly set forth in this Lease, tenants; (iii) making necessary alterations, additions or repairs; and (iv) performing any of Tenant’s obligations when Tenant has failed to do so
after the expiration of any applicable notice and cure period expressly set forth in this Lease. Landlord shall have the right to enter the Leased Premises during normal business hours (or as otherwise agreed), subject to Tenant’s reasonable
security measures, for purposes of supplying any maintenance or services agreed to be supplied by Landlord. Landlord shall have the right to enter the Common Areas during normal business hours for purposes of (i) inspecting the exterior of the
Building and the Common Areas; (ii) posting notices of nonresponsibility (and for such purposes Tenant shall provide Landlord at least ten (10) days’ prior written notice of any work to be performed on the Leased Premises, as well as
notice within one (1) day after the commencement of such work); and (iii) supplying any services to be provided by Landlord. Landlord shall also have the right, upon reasonable advance notice to Tenant, to access the Building’s
vertical risers and the interstitial space above Tenant’s acoustical ceiling to connect new utility and communications lines from other floors to the base Building utility lines; all of such work shall be done after hours or on weekends. Any
entry into the Leased Premises or the Common Areas obtained by Landlord in accordance with this paragraph shall not under any circumstances be construed or deemed to be a forcible or unlawful entry into, or a detainer of, the Leased Premises, or an
eviction, actual or constructive of Tenant from the Leased Premises or any portion thereof. Landlord shall conduct all of Landlord’s activities on the Leased Premises during such period of entry in a manner designed to cause minimal
interference to Tenant and Tenant’s use of the Leased Premises. 
 4.10 Use Of Common Areas. Tenant, in its use of the Common
Areas, shall at all times keep the Common Areas clear of Tenant’s and the Tenant Parties’ materials, equipment, debris, trash (except within existing enclosed trash areas), inoperable vehicles, and other items which are not specifically
permitted by Landlord to be stored or located thereon by Tenant. If, in the opinion of Landlord, unauthorized persons are using any of the Common Areas by reason of, or under claim of, the express or implied authority or consent of Tenant, then
Tenant, upon demand of Landlord, shall restrain, to the fullest extent then allowed by Law, such unauthorized use, and shall initiate such appropriate proceedings as may be required to so restrain such use. Landlord reserves the right to grant
easements and access rights to others for use of the Common Areas so long as the Required Conditions are satisfied, and shall not be liable to Tenant for any diminution in Tenant’s right to use the Common Areas as a result. 

  
 15 

 Building D 
  

4.11 Environmental Protection. Tenant’s obligations under this Paragraph 4.11 shall survive the expiration or termination of this
Lease. 
 (a) As used herein, the term “Hazardous Materials” shall mean any toxic or hazardous substance, material or waste
or any pollutant or infectious or radioactive material, including but not limited to those substances, materials or wastes regulated now or in the future under any of the following statutes or regulations and any and all of those substances included
within the definitions of “hazardous substances,” “hazardous materials,” “hazardous waste,” “hazardous chemical substance or mixture,” “imminently hazardous chemical substance or mixture,”
“toxic substances,” “hazardous air pollutant,” “toxic pollutant,” or “solid waste” in the (a) Comprehensive Environmental Response, Compensation and Liability Act of 1990 (“CERCLA” or
“Superfund”), as amended by the Superfund Amendments and Reauthorization Act of 1986 (“SARA”), 42 U.S.C. § 9601 et seq., (b) Resource Conservation and Recovery Act of 1976 (“RCRA”), 42 U.S.C. §
6901 et seq., (c) Federal Water Pollution Control Act (“FSPCA”), 33 U.S.C. § 1251 et seq., (d) Clean Air Act (“CAA”), 42 U.S.C. § 7401 et seq., (e) Toxic Substances Control Act
(“TSCA”), 14 U.S.C. § 2601 et seq., (f) Hazardous Materials Transportation Act, 49 U.S.C. § 1801, et seq., (g) Carpenter-Presley-Tanner Hazardous Substance Account Act (“California Superfund”),
Cal. Health & Safety Code § 25300 et seq., (h) California Hazardous Waste Control Act, Cal. Health & Safety code § 25100 et seq., (i) Porter-Cologne Water Quality Control Act (“Porter-Cologne
Act”), Cal. Water Code § 13000 et seq., (j) Hazardous Waste Disposal Land Use Law, Cal. Health & Safety codes § 25220 et seq., (k) Safe Drinking Water and Toxic Enforcement Act of 1986
(“Proposition 65”), Cal. Health & Safety code § 25249.5 et seq., (l) Hazardous Substances Underground Storage Tank Law, Cal. Health & Safety code § 25280 et seq., (m) Air Resources Law,
Cal. Health & Safety Code § 39000 et seq., and (n) regulations promulgated pursuant to said laws or any replacement thereof, or as similar terms are defined in the federal, state and local laws, statutes, regulations,
orders or rules. Hazardous Materials shall also mean any and all other biohazardous wastes and substances, materials and wastes which are, or in the future become, regulated under applicable Laws for the protection of health or the environment, or
which are classified as hazardous or toxic substances, materials or wastes, pollutants or contaminants, as defined, listed or regulated by any federal, state or local law, regulation or order or by common law decision, including, without limitation,
(i) trichloroethylene, tetrachloroethylene, perchloroethylene and other chlorinated solvents, (ii) any petroleum products or fractions thereof, (iii) asbestos, (iv) polychlorinated biphenyls, (v) flammable explosives,
(vi) urea formaldehyde, (vii) radioactive materials and waste, and (viii) materials and wastes that are harmful to or may threaten human health, ecology or the environment. 

(b) Notwithstanding anything to the contrary in this Lease, Tenant, at its sole cost, shall comply with, and shall cause the Tenant Parties to
comply with, all Laws relating to the storage, use and disposal of Hazardous Materials at the Property; provided, however, that Tenant shall not be responsible for contamination of the Leased Premises and/or the Building, the Property, or the
Project (including the Parking Structure) by Hazardous Materials existing as of the date the Leased Premises are delivered to Tenant (whether before or after the Lease Commencement Date) excepting only contamination caused by Tenant or the Tenant
Parties. Tenant shall not store, use or dispose of any Hazardous Materials except for ordinary office and cleaning supplies used in compliance with all Laws and Restrictions (“Office & Cleaning Supplies”). In no event shall
Tenant cause, or permit to be discharged by any of the Tenant Parties, into the plumbing or sewage system of the Building or onto the land underlying or adjacent to the Building, any Hazardous Materials. Tenant shall be solely responsible for and
shall defend, indemnify, and hold Landlord and its agents harmless from and against all claims, costs and liabilities, including reasonable attorneys’ fees and costs, arising out of or in connection with Tenant’s storage, use and/or
disposal of Hazardous Materials at the Project. If the presence of Hazardous Materials on the Leased Premises caused by Tenant or any of the Tenant Parties results in contamination or deterioration of water or soil, then Tenant shall promptly take
any and all action necessary to clean up such contamination, but the foregoing shall in no event be deemed to constitute permission by Landlord to allow the presence of such Hazardous Materials. At any time prior to the expiration of the Lease Term
if Tenant has a reasonable basis to suspect that there has been any release or the presence of Hazardous Materials in the ground or ground water on the Leased Premises which did not exist upon commencement of the Lease Term, Tenant shall have the
right to conduct appropriate tests of water and soil and to deliver to Landlord the results of such tests to demonstrate that no contamination in excess of permitted levels has occurred as a result of Tenant’s use of the Leased Premises. Tenant
shall further be solely responsible for, and shall defend, indemnify, and hold Landlord and its agents harmless from and against all claims, costs and liabilities, including attorneys’ fees and costs, arising out of or in connection with any
removal, cleanup and restoration work and materials required hereunder to return the Leased Premises and any other property of whatever nature to their condition existing prior to the appearance of the Hazardous Materials, to the extent such
Hazardous Materials were introduced to the Property or the Project by Tenant or any of the Tenant Parties. 
 (c) Upon termination or
expiration of the Lease Term, Tenant at its sole expense shall cause all Hazardous Materials placed in or about the Leased Premises, the Building and/or the Property by Tenant or any of the Tenant Parties, and all installations (whether interior or
exterior) made by or on behalf of Tenant or any of the Tenant Parties relating to the storage, use, disposal or 

  
 16 

 Building D 
  

transportation of Hazardous Materials to be removed from the property and transported for use, storage or disposal in accordance and compliance with all Laws and other requirements respecting
Hazardous Materials used or permitted to be used by Tenant. If Tenant uses any Hazardous Materials other than Office & Cleaning Supplies, then Tenant shall apply for and shall obtain from all appropriate regulatory authorities (including
any applicable fire department or regional water quality control board) all permits, approvals and clearances necessary for the closure of the Property and the Project and shall take all other actions as may be required to complete the closure of
the Building, the Property, and the Project. 
 (d) At any time prior to expiration of the Lease Term, subject to reasonable prior notice
(not less than forty-eight (48) hours) and Tenant’s reasonable security requirements and provided such activities do not unreasonably interfere with the conduct of Tenant’s business at the Leased Premises, Landlord shall have the
right to enter in and upon the Property, Building and Leased Premises in order to conduct appropriate tests of water and soil to determine whether levels of any Hazardous Materials in excess of legally permissible levels has occurred as a result of
Tenant’s use thereof. Landlord shall furnish copies of all such test results and reports to Tenant and, at Tenant’s option and cost, shall permit split sampling for testing and analysis by Tenant. Such testing shall be at Tenant’s
expense if Landlord has a reasonable basis for suspecting and confirms the presence of Hazardous Materials in the soil or surface or ground water in, on, under, or about the Property, the Building or the Leased Premises, which has been caused by or
resulted from the activities of Tenant or any of the Tenant Parties. 
 (e) Landlord may voluntarily cooperate in a reasonable manner with
the efforts of all governmental agencies in reducing actual or potential environmental damage. Tenant shall not be entitled to terminate this Lease or to any reduction in or abatement of rent by reason of such voluntary cooperation, nor for any
required compliance. Tenant agrees at all times to cooperate fully with the requirements and recommendations of governmental agencies regulating, or otherwise involved in, the protection of the environment, provided that Tenant is not required to
incur any liability or more than de minimus expense in connection therewith. 
 4.12 Rules And Regulations. Landlord shall have the
right from time to time to establish reasonable and non-discriminatory rules and regulations and/or amendments or additions thereto respecting the use of the Building and the Common Areas for the care and orderly management of the Property. No rules
and regulations shall require Tenant to pay rent nor shall any such rules and regulations apply retroactively. Upon delivery to Tenant of a copy of such rules and regulations or any amendments or additions thereto, Tenant shall comply with such
rules and regulations. A violation by Tenant of any of such rules and regulations shall constitute a default by Tenant under this Lease. If there is a conflict between the rules and regulations and any of the provisions of this Lease, the provisions
of this Lease shall prevail. Landlord shall not be responsible or liable to Tenant for the violation of such rules and regulations by any other tenant of the Property. 

4.13 Reservations. Landlord reserves the right from time to time to grant, without the consent or joinder of Tenant, such easements,
rights of way and dedications that Landlord deems necessary, and to cause the recordation of parcel maps and restrictions, so long as such easements, rights of way and dedications do not unreasonably interfere with the use of the Leased Premises by
Tenant and the Required Conditions are satisfied. Tenant agrees to execute any documents reasonably requested by Landlord to effectuate any such easement rights, dedications, maps or restrictions. 

4.14 Roof. Subject to Paragraph 2.1 above, notwithstanding any provision of this Lease to the contrary, Landlord hereby reserves to
itself and its other tenants in the Project all rights of access, use and occupancy of the Building roof, and Tenant shall have no right of access, use or occupancy of the Building roof except (if at all) to the extent provided in this Paragraph
4.14. Landlord will designate a portion of the roof to hold a rooftop equipment pad (a “Roof Pad”) for installations by tenants of the Building (the “Available Rooftop Space”). Tenant shall be entitled to utilize
Tenant’s Building Share of the Available Rooftop Space as follows: 
 (a) Subject to Tenant’s restoration and repair obligations
under Paragraph 2.6, Tenant at its sole cost and expense shall have the right to install within Tenant’s Building Share of the Available Rooftop Space, mechanical and electrical equipment and satellite dishes, television antennas, and related
cable connections (collectively, “Rooftop Equipment”) required in connection with Tenant’s own business and communications and data transmission network, in an area to be reasonably agreed upon by Landlord and Tenant in the
Available Rooftop Space, provided such installation does not impact the structural integrity of the Building, is not inconsistent with the Project aesthetics, and does not void or negatively impact any applicable warranties. 

(b) Tenant shall supply Landlord with detailed plans and specifications of the Rooftop Equipment prior to the installation thereof for
Landlord’s review and approval. Furthermore, Tenant shall have secured Landlord’s approval and the approval of all governmental authorities and all permits required by governmental authorities having jurisdiction over such approvals and
permits for the 

  
 17 

 Building D 
  

Rooftop Equipment, and shall provide copies of such approvals and permits to Landlord prior to commencing any work with respect to such Rooftop Equipment. Tenant shall pay for any and all costs
and expenses in connection with, and shall repair all damage to the roof resulting from, the installation, maintenance, use and removal of the Rooftop Equipment. 

4.15 Back-Up Generator. Subject to complying with Paragraphs 2.6 and 6.1, Tenant shall have the right to install a backup generator and
certain other mechanical equipment in the Available Rooftop Space or in another location mutually agreed to by the parties, subject to Landlord’s approval in its sole but good faith discretion, of its design (including aesthetic screening) and
construction, and of any connections between the Leased Premises and such generator and any penetrations to the Building walls, roof, or structure required in connection therewith. If such backup generator or other mechanical equipment is located on
any parking areas on the Project, then such lost parking spaces shall be counted towards satisfying Tenant’s parking allocation under Article 1 hereof. 

ARTICLE 5 
 REPAIRS,
MAINTENANCE, SERVICES AND UTILITIES 
 5.1 Repair And Maintenance. Except in the case of damage to or destruction of the Leased
Premises, the Building, the Common Areas, the Property, or the Project caused by an act of God or other peril, in which case the provisions of Article 10 shall control, the parties shall have the following obligations and responsibilities with
respect to the repair and maintenance of the Leased Premises, the Building, the Common Areas,, the Property, and the Project. 
 (a)
Tenant’s Obligations. Tenant shall, at all times during the Lease Term and at its sole cost and expense, regularly clean and continuously keep and maintain in good order, condition and repair the interior, non-structural portions of the
Leased Premises and every part thereof, including, without limiting the generality of the foregoing, (i) all interior walls, floors and ceilings, (ii) all interior windows, doors and skylights, (iii) all electrical wiring, conduits,
connectors and fixtures within the Leased Premises, (iv) all interior sinks, toilets, and faucets and, to the extent serving just the Leased Premises, plumbing, pipes, and drains, (v) all interior lighting fixtures, bulbs and lamps,
(vi) any back-up generator(s), HVAC equipment, or other equipment installed by or at the request of Tenant, (vii) all entranceways to the Leased Premises with respect to which Tenant and the Tenant Parties have exclusive access rights, and
(viii) the Building elevator(s) during any period that Tenant is leasing the entire rentable square footage of the Building; provided, however, that Tenant shall not be required to maintain, repair, and replace those items which are
Landlord’s obligation to maintain, repair, and replace pursuant to Paragraph 5.1(b) below. Tenant shall, at Tenant’s sole cost and expense, provide for its own janitorial service for the Leased Premises. Subject to Paragraph 9.3 below,
Tenant shall, at its sole cost and expense, repair all damage to the Leased Premises, the Building, the Common Areas, the Property, or the Project caused by the activities of Tenant or any of the Tenant Parties promptly following written notice from
Landlord to so repair such damages. If Tenant shall fail to perform the required maintenance or fail to make repairs required of it pursuant to this paragraph within the notice and cure periods specified in Paragraph 12.1(b) below, then Landlord
may, at its election and without waiving any other remedy it may otherwise have under this Lease or at law, perform such maintenance or make such repairs and charge to Tenant, as Additional Rent, the costs so incurred by Landlord for same. All
interior glass within or a part of the Leased Premises is at the sole risk of Tenant and any broken glass shall promptly be replaced by Tenant at Tenant’s expense with glass of the same kind, size and quality. 

(b) Landlord’s Obligation. Landlord shall, at all times during the Lease Term, maintain in good condition and repair the Common
Areas, the foundation, slabs, roof structure and membrane, curtain walls and load-bearing and exterior walls of the Building, and (i) HVAC equipment (except as described in clause (vi) of Paragraph 5.1(a) above), and (ii) plumbing,
pipes, and drains, to the extent the items described in clauses (i) and (ii), serve both the Leased Premises and other portions of the Property. Landlord may hire a licensed HVAC contractor to regularly and periodically inspect and perform
required maintenance on the HVAC equipment and systems serving the Leased Premises and/or the Building. Landlord may also hire a licensed roofing contractor to regularly and periodically inspect and perform required maintenance on the roof of the
Building. Landlord shall keep the Common Areas in a clean condition. Landlord shall regularly and periodically sweep and clean the driveways and parking areas. Unless necessitated by the acts or omissions of Tenant or any of the Tenant Parties
(subject to the terms of Paragraph 9.3 below), Landlord shall make any necessary (x) structural repairs or structural replacements to the Leased Premises and (y) repairs or replacements to (i) any fire alarm and communication system
in the Leased Premises installed by Landlord, (ii) the electrical, plumbing, and mechanical portions of the Warm Shell Components as defined in the Work Letter), (iii) the Building elevator(s) except during any period that Tenant is
leasing the entire rentable square footage of the Building, and (iv) any sprinkler system installed by Landlord in the Leased Premises; if any of the foregoing are necessitated by the acts or negligent or wrongful omissions of Tenant or any of
the Tenant Parties (subject to Paragraph 9.3 below), Tenant shall reimburse to Landlord, within thirty (30) days after receipt of the applicable invoices, the cost incurred by Landlord in connection therewith. The provisions of this
subparagraph (b) shall in no way limit the right of Landlord to charge to Tenant, as Additional 

  
 18 

 Building D 
  

Rent pursuant to Article 3, the costs incurred by Landlord in performing such maintenance and/or inspections, and/or in making such repairs or replacements; provided, however, that
(1) Tenant shall not be responsible for any capital repairs or replacements costing over $10,000 individually, which are incurred by Landlord during the initial, unextended Lease Term, except to the extent such capital repairs or replacements
are necessitated by Tenant’s breach of this Lease), and (2) with respect to capital repairs or replacements costing less than $10,000 individually during the initial, unextended Lease Term, Tenant shall pay the full amount thereof until in
any twelve (12) month period Tenant has paid $50,000 on such capital repairs or replacements, and thereafter for the balance of such twelve (12) month period, Landlord shall pay for such capital repairs or replacements and the cost
incurred by Landlord, including interest at a rate equal to the Standard Interest Rate, shall be amortized by Landlord over the useful life of such capital repairs or replacements, as determined in accordance with generally accepted accounting
principles, and the monthly amortized cost of such capital repairs or replacements as so amortized shall be considered a Property Maintenance Cost. The entire foregoing proviso shall expire and be of no further force or effect after the initial
unextended Lease Term has expired (i.e., it shall not be applicable during any extension periods). 
 5.2 Utilities. 

(a) Subject to Paragraph 5.2(b) below: Tenant shall arrange at its sole cost and expense and in its own name, for the supply of water, gas and
electricity to the Leased Premises and Landlord shall not have responsibility for the delivery same to Tenant; provided, however, that Landlord hereby warrants that the Building, as built by Landlord, shall have an electrical capacity of at
least eight (8) watts per rentable square foot of space in the Leased Premises. Tenant shall be responsible for determining if the local supplier of water, gas and electricity can supply the needs of Tenant and whether or not the existing
water, gas and electrical distribution systems within the Building and the Leased Premises are adequate for Tenant’s needs. Tenant shall be responsible for determining if the existing sanitary and storm sewer systems now servicing the Leased
Premises and the Property are adequate for Tenant’s needs. Tenant shall pay all charges for water, gas, electricity and storm and sanitary sewer services as so supplied to the Leased Premises, irrespective of whether or not the services are
maintained in Landlord’s or Tenant’s name. 
 (b) In the event Tenant does not lease the sixth floor of the Building by the end of
the Hold-Off Period (as defined in Article 17 below): 
 (i) Landlord will coordinate with Tenant for the supply of gas, water, and
electricity to the Leased Premises during Building Standard Hours, but shall not have responsibility for the delivery same to Tenant. 

(ii) Landlord shall, at its sole expense, install sub-meters and connect them to the Building energy management system to monitor
Tenant’s electric use. Upon Tenant’s request either (x) via the energy management system serving the Leased Premises, or (y) during Building Standard Hours, by 10:00 a.m. on any day for after-hours usage on that same day, and by
10:00 a.m. on Friday for after-hours usage on weekends or holidays, and subject to the payment obligations described below, Landlord agrees to make HVAC available to Tenant outside of Building Standard Hours. 

(c) Tenant shall pay: (i) for all of its consumption of electricity, gas and water within the Leased Premises, either directly pursuant
to Paragraph 5.2(a) above or as reasonably determined by Landlord based on the data from the sub-meter for electricity, and on a pro rata basis for gas and water service; and (ii) subject to Paragraph 5.2(d) below, (A) Tenant’s
Building Share of all Building utilities relating to HVAC, elevators, and Common Areas within the Building consumed during Building Standard Hours, and (B) Landlord’s reasonable estimate of the actual cost (including depreciation over the
useful life of the item in question) for all of such utilities described in clause (ii)(A) consumed by Tenant outside of Building Standard Hours as reasonably determined by Landlord based on the number of tenants utilizing such utilities, the
relative square footages of their respective leased premises, and the duration of their use. In no event shall the cost charged to Tenant for utilities used after Building Standard Hours include any profit or mark-up to Landlord. There shall be no
minimum number of hours required in charging Tenant such cost for utilities used after Building Standard Hours. Costs of utilities payable to Landlord shall be paid by Tenant within twenty (20) days after invoice therefor from time to time, or,
at Landlord’s option, with respect to utility costs other than after hours HVAC and submetered electricity, shall be included in Property Maintenance Costs or, with respect to the portion of electricity use that is submetered, shall be paid in
estimated monthly installments subject to annual reconciliation in like fashion as for Property Maintenance Costs. 
 (d) The costs to be
paid by Tenant to Landlord Paragraph 5.2(c) above (as opposed to directly pursuant to Paragraph 5.2(a) above) are based on Tenant’s HVAC use being what is currently typical of office users for heating and cooling of generic office space, and on
such use specifically excluding continuous, near continuous, or heavy use (“Above-Standard Use”) of the HVAC. Any Above-Standard Use (e.g., uses such as network operations centers, server rooms, and data centers) will

  
 19 

 Building D 
  

require dedicated HVAC and separately metered utilities. Notwithstanding any other provision of this Lease, Tenant, at its sole cost and expense, and in accordance with Article 6 below, will
contract for directly and cause to be installed any such dedicated HVAC equipment (including separate meters), and shall be solely responsible for all ongoing maintenance, service, repairs, replacements, and utility charges related to such dedicated
HVAC. 
 5.3 Security. Tenant acknowledges that Landlord has not undertaken any duty whatsoever to provide security for the Leased
Premises, the Building, the Common Areas, the Property, or the Project and, accordingly, Landlord is not responsible for the security of same or the protection of Tenant’s property or any of the Tenant Parties from any cause whatsoever,
including but not limited to criminal and/or terrorist acts. To the extent Tenant determines that such security or protection services are advisable or necessary, Tenant shall arrange for and pay the costs of providing same. In the event Landlord in
its sole and absolute discretion agrees to provide any security services, whether it be guard service or access systems or otherwise, Landlord shall do so strictly as an accommodation to Tenant and Landlord shall have no liability whatsoever in
connection therewith, whether it be for failure to maintain the secure access system, or for failure of the guard service to provide adequate security, or otherwise. Without limitation, Paragraph 8.1 below is intended by Tenant and Landlord to apply
to this Paragraph 5.3. 
 5.4 Energy And Resource Consumption. 

(a) Energy Consumption Reduction Efforts. Tenant shall comply with the Building Energy Management System and Utility Metering
requirements set forth in the Work Letter. In addition, Landlord may voluntarily cooperate in a reasonable manner with the efforts of governmental agencies and/or utility suppliers in reducing energy or other resource consumption within the
Property. Tenant shall not be entitled to terminate this Lease or to any reduction in or abatement of rent by reason of such cooperation. Tenant agrees at all times to cooperate fully with Landlord and to abide by all reasonable rules established by
Landlord (i) in order to maximize the efficient operation of the electrical, and HVAC systems and all other energy or other resource consumption systems with the Property and the Project and/or (ii) in order to comply with the
recommendations of utility suppliers and governmental agencies regulating the consumption of energy and/or other resources. 
 (b) Tenant
Utility Usage Data Reporting. If Tenant is billed directly by a utility company with respect to Tenant’s electricity and natural gas/propane usage data at the Leased Premises, then, promptly following Landlord’s written request, Tenant
shall provide its monthly electricity and natural gas/propane usage data for the Leased Premises to Landlord for the period of time requested by Landlord (in electronic or paper format) or, at Landlord’s option, provide any written
authorization or other documentation required for Landlord to request information regarding Tenant’s electricity and natural gas/propane usage data with respect to the Leased Premises directly from the utility company. 

5.5 Limitation Of Landlord’s Liability. Landlord shall not be liable to Tenant for injury to Tenant or any of the Tenant Parties,
or damage to property of Tenant or any Tenant Parties, or loss of Tenant’s or any Tenant Parties’ business or profits, nor shall Tenant be entitled to terminate this Lease or to any reduction in or abatement of rent, except as provided for
below, by reason of (i) Landlord’s failure to provide security services or systems within the Property or the Project for the protection of the Leased Premises, the Building or the Common Areas, or the protection of Tenant’s property
or any of the Tenant Parties, or (ii) Landlord’s failure to perform any maintenance or repairs to the Leased Premises, the Building, the Common Areas, the Property, or the Project within the notice and cure periods set forth in Paragraph
12.3 below, or (iii) any failure, interruption, rationing or other curtailment in the supply of water, electric current, gas or other utility service to the Leased Premises, the Building, the Common Areas, the Property, or the Project from
whatever cause (other than Landlord’s active gross negligence or willful misconduct), or (iv) the unauthorized intrusion or entry into the Leased Premises by third parties (other than Landlord). Notwithstanding the foregoing, in the event
that Tenant is prevented from using, and does not use, the Leased Premises or any portion thereof as a result of a Trigger Event (as defined below), then Tenant shall give Landlord written notice thereof and if such Trigger Event continues for five
(5) consecutive business days (such period herein called the “Eligibility Period”), then Tenant’s Base Monthly Rent and Tenant’s obligation to pay Project Operating Expenses shall be abated or reduced, as the case may
be, after expiration of the Eligibility Period for such period of time that Tenant continues to be so prevented from using, and does not actually use, the Leased Premises or a portion thereof, in the proportion that the rentable area of the portion
of the Leased Premises that Tenant is prevented from using bears to the total rentable area of the Leased Premises. As used herein, the term “Trigger Event” means any of the following events: (1) any failure by Landlord to
provide Tenant with access to the Leased Premises or the Project that materially impacts or interrupts Tenant’s use of the Leased Premises, unless such failure is a result of any Laws or Restrictions, (2) Landlord’s failure to perform
Landlord’s repair and maintenance obligations hereunder if such failure continues beyond any applicable notice and cure period and (3) a disruption of utilities to the Leased Premises, and such disruption is caused solely by the
intentional acts, negligence or willful misconduct of Landlord or any of Landlord’s Parties. 

  
 20 

 Building D 
  

ARTICLE 6 
 ALTERATIONS
AND IMPROVEMENTS 
 6.1 By Tenant. This Paragraph 6.1 does not relate to the Tenant Improvements installed in accordance with and
pursuant to the Work Letter, but to alterations, modifications, and improvements made after the date the Tenant Improvements are substantially completed. Tenant shall not make any Non-Standard Office Improvements until Landlord shall have first
approved, in writing, the plans and specifications therefor, which approval may be withheld in Landlord’s sole discretion as to Non-Standard Office Improvements which affect the Building façade, structure, or systems, and otherwise such
approval may be withheld in Landlord’s reasonable discretion. Landlord’s written approval shall, if applicable, also contain Landlord’s election to require Tenant to remove the subject Non-Standard Office Improvements at the
expiration or earlier termination of this Lease, in which event Tenant shall be obligated to do so. All modifications, alterations or improvements shall be made, constructed or installed by Tenant at Tenant’s expense (including all permit fees
and governmental charges related thereto), using a licensed contractor first approved by Landlord which approval shall not be unreasonably withheld or delayed, in substantial compliance with the Landlord-approved plans and specifications therefor.
All work undertaken by Tenant shall be done in accordance with all Laws and Restrictions and in a good and workmanlike manner using new materials of good quality. Tenant shall not commence the making of any such modifications or alterations or the
construction of any such improvements until (i) any and all required governmental approvals and permits shall have been obtained, (ii) all requirements regarding insurance imposed by this Lease have been satisfied, (iii) Tenant shall
have given Landlord at least five (5) business days prior written notice of its intention to commence such work so that Landlord may post and file notices of non-responsibility, and (iv) if requested by Landlord, Tenant shall have obtained
contingent liability and broad form builder’s risk insurance in an amount satisfactory to Landlord in its reasonable discretion to cover any perils relating to the proposed work not covered by insurance carried by Tenant pursuant to Article 9.
In no event shall Tenant make any modification, alterations or improvements whatsoever to the Common Areas (except the Exclusive Use Common Areas). As used in this Article, the term “modifications, alterations and/or improvements”
shall include, without limitation, the installation of additional electrical outlets, overhead lighting fixtures, drains, sinks, partitions, doorways, or the like. Notwithstanding the foregoing, Tenant, without Landlord’s prior written consent,
shall be permitted to make alterations to the Leased Premises which are not Non-Standard Office Improvements provided that: (a) Tenant shall timely provide Landlord the notices required pursuant to Paragraph 4.9 above, (b) Tenant shall
have secured the approval of all governmental authorities and all permits required by governmental authorities having jurisdiction over such approvals and permits for such alterations, and shall provide copies of such approvals and permits to
Landlord prior to commencing any work with respect to such alterations, and (c) Tenant shall notify Landlord in writing within thirty (30) days of completion of the alteration and deliver to Landlord a set of the plans and specifications
therefor, either “as built” or marked to show construction changes made. 
 6.2 Ownership Of Improvements. All
modifications, alterations and improvements made or added to the Leased Premises by Tenant (other than Tenant’s inventory, equipment, movable furniture, wall decorations and trade fixtures) shall be deemed real property and a part of the Leased
Premises, but shall remain the property of Tenant during the Lease Term (which includes any extension(s) thereof pursuant to Article 15 below, if applicable). At the expiration or sooner termination of this Lease, all such modifications, alterations
and improvements other than Tenant’s inventory, equipment, movable furniture, wall decorations and trade fixtures, shall automatically become the property of Landlord and shall be surrendered to Landlord as part of the Leased Premises as
required pursuant to Article 2, unless Landlord shall require Tenant to remove any of such modifications, alterations or improvements which constitute Non-Standard Office Improvements in accordance with the provisions of Article 2, in which case
Tenant shall so remove same. Landlord shall have no obligations to reimburse Tenant for all or any portion of the cost or value of any such modifications, alterations or improvements so surrendered to Landlord. All modifications, alterations or
improvements which are installed or constructed on or attached to the Leased Premises by Landlord and/or at Landlord’s expense shall be deemed real property and a part of the Leased Premises and shall be property of Landlord; provided,
however, that the Tenant Improvements (as defined in Paragraph 2 of the Work Letter) shall become Landlord’s property only upon the expiration or earlier termination of the Lease Term. All lighting, plumbing, electrical, HVAC fixtures,
partitioning, window coverings, wall coverings and floor coverings installed by Tenant shall be deemed improvements to the Leased Premises and not trade fixtures of Tenant. 

6.3 Alterations Required By Law. 

(a) Landlord at its sole cost shall make all modifications, alterations and improvements to the Building, the Property, or the Project, that
are required by any governmental authority at any time due to the base Building constructed by Landlord not having been in compliance with the Laws then applicable governing its construction. 

(b) Tenant at its sole cost shall make all modifications, alterations and improvements to the Leased Premises, the Building, the Common Areas,
the Property, or the Project that are required by 

  
 21 

 Building D 
  

any Law because of (i) Tenant’s particular use or occupancy of the Leased Premises, the Building, the Common Areas, the Property, or the Project (as opposed to the Permitted Use
generally), (ii) Tenant’s application for any permit or governmental approval, or (iii) Tenant’s making of any modifications, alterations or improvements to or within the Leased Premises. 

(c) If Landlord shall, at any time during the Lease Term, be required by any governmental authority or Law to make any modifications,
alterations or improvements to the Building, the Property, or the Project, the cost incurred by Landlord in making such modifications, alterations or improvements, including interest at a rate equal to the Standard Interest Rate shall be amortized
by Landlord over the useful life of such modifications, alterations or improvements, as determined in accordance with generally accepted accounting principles, and the monthly amortized cost of such modifications, alterations and improvements as so
amortized shall be considered a Property Maintenance Cost. For purposes of this paragraph 6.3(c) only, the useful life of the applicable modifications, alterations or improvements shall be a minimum of fifteen (15) years, and in no event shall
Tenant be required to pay more than $100,000 per year on account of any monthly amortization payments arising pursuant to this paragraph 6.3(c). 

6.4 Liens. Tenant shall keep the Property and the Project and every part thereof free from any lien, and shall pay when due all bills
arising out of any work performed, materials furnished, or obligations incurred by Tenant, its agents, employees or contractors relating to the Property. If any such claim of lien is recorded against Tenant’s interest in this Lease, the
Property or any part thereof, Tenant shall bond against, discharge or otherwise cause such lien to be entirely released within ten (10) days after the same has been recorded. Tenant’s failure to do so shall be conclusively deemed a
material default under the terms of this Lease. 
 ARTICLE 7 

ASSIGNMENT AND SUBLETTING BY TENANT 

7.1 By Tenant. Tenant shall not sublet the Leased Premises or any portion thereof or assign its interest in this Lease, or permit the
occupancy of the Premises by other than Tenant, whether voluntarily or by operation of Law, without Landlord’s prior written consent which shall not be unreasonably withheld and shall be given within the time periods set forth in Paragraph 7.3
below. Any attempted subletting or assignment, or occupancy of the Leased Premises by other than Tenant, without Landlord’s prior written consent, at Landlord’s election, shall constitute a default by Tenant under the terms of this Lease.
The acceptance of rent by Landlord from any person or entity other than Tenant, or the acceptance of rent by Landlord from Tenant with knowledge of a violation of the provisions of this paragraph, shall not be deemed to be a waiver by Landlord of
any provision of this Article or this Lease or to be a consent to any subletting by Tenant or any assignment of Tenant’s interest in this Lease. Without limiting the circumstances in which it may be reasonable for Landlord to withhold its
consent to an assignment or subletting, Landlord and Tenant acknowledge that it shall be reasonable for Landlord to withhold its consent in the following instances: 

(a) the proposed assignee or sublessee is a governmental agency; 

(b) in Landlord’s reasonable judgment, the use of the Leased Premises by the proposed assignee or sublessee would involve occupancy other
than for a Permitted Use, would entail any alterations which would lessen the value of the leasehold improvements in the Leased Premises, or would require increased services by Landlord; 

(c) the credit-worthiness of the proposed assignee does not meet the credit standards applied by Landlord, which standards shall take into
account the fact that Aruba Networks, Inc. continues to be liable for the obligations of the assignee under this Lease; 
 (d) the proposed
assignee or sublessee (or any of its affiliates) has been in material default under a lease, has been in litigation with a previous landlord, or in the ten (10) years prior to the assignment or sublease has filed for bankruptcy protection, has
been the subject of an involuntary bankruptcy, or has been adjudged insolvent; 
 (e) Landlord (or any of its affiliates) has experienced a
previous default by or is in litigation with the proposed assignee or sublessee (or any of their affiliates); 
 (f) in Landlord’s
reasonable judgment, the Leased Premises, or the relevant part thereof, will be used in a manner that will violate any negative covenant as to use contained in this Lease; 

(g) the use of the Leased Premises by the proposed assignee or sublessee will violate any Law or Restriction; 

  
 22 

 Building D 
  

(h) the proposed assignee or sublessee is a tenant at the Project and there is competing space available within the Project which is suitable
for the needs of such assignee or sublessee; 
 (i) the proposed assignment or sublease fails to include all of the terms and provisions
required to be included therein pursuant to this Article 7; 
 (j) Tenant is in monetary or material non-monetary default of any obligation
of Tenant under this Lease; or 
 (k) in the case of a subletting of less than the entire Leased Premises, if the subletting would result in
the division of the Leased Premises into more than two subparcels or would require improvements to be made outside of the Leased Premises. 

7.2 Merger, Reorganization, or Sale of Assets. 

(a) Subject to Paragraphs 7.2(b) and 7.9 below: Any dissolution, merger, consolidation or other reorganization of Tenant, or the sale or other
transfer in the aggregate over the Lease Term of a controlling percentage of the capital stock of or other equity interests in Tenant, or the sale or transfer of all or a substantial portion of the assets of Tenant, shall be deemed a voluntary
assignment of Tenant’s interest in this Lease. The phrase “controlling percentage” means the direct or indirect ownership of or right to vote (i) stock possessing more than fifty percent of the total combined voting power
of all classes of Tenant’s capital stock issued, outstanding and entitled to vote for the election of directors, or (ii) equity interests possessing the ability to direct the management of Tenant. If Tenant is a partnership, a withdrawal
or change, voluntary, involuntary or by operation of Law, of any general partner, or the dissolution of the partnership, shall be deemed a voluntary assignment of Tenant’s interest in this Lease. Upon Landlord’s request from time to time,
Tenant shall promptly provide Landlord with a statement certified by the Tenant’s chief executive officer or chief operating officer, which shall provide the following information: (i) the names of all of Tenant’s shareholders and
their ownership interests at the time thereof, provided Tenant’s shares are not publicly traded; (ii) the state in which Tenant is incorporated; (iii) the location of Tenant’s principal place of business; (iv) information
regarding a material change in the corporate structure of Tenant, including, without limitation, a merger or consolidation; and (v) any other information regarding Tenant’s ownership that Landlord reasonably requests. In the event of an
acquisition by one entity of the controlling percentage of the capital stock of Tenant where this Lease is not assigned to and assumed in full by such entity, it shall be a condition to Landlord’s consent to such change in control that such
entity acquiring the controlling percentage assume, as a primary obligor, all rights and obligations of Tenant under this Lease (and such entity shall execute all documents reasonably required to effectuate such assumption). 

(b) Notwithstanding subparagraph (a) above, over-the-counter stock market transactions shall not be deemed to be assignments under this
Lease. In addition, provided that the conditions described below in this sentence have been satisfied prior to or upon such assignment or subleasing, Tenant may, without Landlord’s prior written consent, sublet the Leased Premises or assign
this Lease to a “Permitted Transferee,” defined herein as (i) a subsidiary, affiliate, division, corporation or joint venture controlling, controlled by or under common control with Tenant, (ii) a successor entity
resulting from a merger, consolidation, or nonbankruptcy reorganization by Tenant, or (iii) a purchaser of substantially all of Tenant’s assets, provided in all cases (i), (ii) and (iii) that (A) the successor entity,
assignee, purchaser or subtenant has a net worth equal to or greater than those of Tenant prior to the Effective Date of this Lease and a liquid net worth sufficient for Tenant to continually perform its obligations under the Lease, and assumes in
writing for the benefit of Landlord, this Lease and all of Tenant’s obligations under this Lease, and (B) the entity with the greatest net worth involved directly or indirectly in the ownership and/or control of the acquiring, merged,
reorganized, or consolidated entity (hereafter, the “Assignee Affiliate”) shall have unconditionally assumed in writing or guaranteed for the benefit of Landlord, in a form acceptable to Landlord, this Lease and all of Tenant’s
obligations under this Lease. If any assignment or subleasing occurs without such an assumption and/or without Landlord’s consent as provided in Paragraph 7.1 above, Tenant shall be deemed for all purposes to be in material default under this
Lease and the Assignee Affiliate (and the successor entity, assignee, purchaser or subtenant) shall for all purposes be deemed to have unconditionally assumed in writing for the benefit of Landlord, this Lease and all of Tenant’s obligations
under this Lease. In all events, Tenant shall remain fully liable under this Lease. 
 7.3 Landlord’s Election. Except as
provided for in Paragraph 7.2 above and Paragraph 7.9 below, if Tenant shall desire to assign its interest under the Lease or to sublet the Leased Premises, Tenant must first notify Landlord, in writing, of its intent to so assign or sublet, at
least twenty (20) days in advance of taking any action with respect thereto. Once Tenant has identified a potential assignee or sublessee, Tenant shall notify Landlord, in writing, of its intent to so assign or sublet, at least twenty
(20) days in advance of the date it intends to so assign its interest in this Lease or sublet the Leased Premises but not sooner than one hundred eighty (180) days in advance of such date, specifying in detail the terms of such proposed
assignment or subletting, including the name of the proposed assignee or sublessee, the 

  
 23 

 Building D 
  

proposed assignee’s or sublessee’s intended use of the Leased Premises, current financial statements (including a balance sheet, income statement and
statement of cash flow, all prepared in accordance with generally accepted accounting principles; provided, however, that, if applicable with respect to a proposed sublessee, during any period that the proposed sublessee actually does not
prepare its financial statements in accordance with generally accepted accounting principles, then financial statements prepared and reviewed by a reputable, third-party, independent certified public accountant shall suffice) of such proposed
assignee or sublessee, the signed letter of intent or term sheet containing the material terms of such assignment or subletting, and such other information as Landlord may reasonably request. Landlord shall have a period of ten (10) business
days following receipt of such notice and the required information within which to do one of the following: (i) consent to such requested assignment or subletting subject to Tenant’s compliance with the conditions set forth in Paragraph
7.4 below, or (ii) refuse to so consent to such requested assignment or subletting, provided that such consent shall not be unreasonably refused, or (iii) terminate this Lease in the case of an assignment, or (in the case of a sublease for
a term expiring less than six (6) months from the Lease Expiration Date and which would bring the total square footage subject to subleases to more than 50% of the Leased Premises’ square footage), terminate this Lease as to the proposed
sublease premises, such termination to be effective on the date specified in Tenant’s notice as the intended effective date of the assignment or subletting. During such ten (10) business day period, Tenant covenants and agrees to supply to
Landlord, upon request, all necessary or relevant information which Landlord may reasonably request respecting such proposed assignment or subletting and/or the proposed assignee or sublessee. In the event of an election to terminate this Lease by
Landlord under clause (iii) above, Landlord shall have the right to enter into a direct lease with the proposed assignee or sublessee without payment of any consideration to Tenant. If Landlord fails to respond by the end of such ten
(10) business day period to Tenant’s request for consent to any proposed Transfer, Tenant may send a second (2nd) request to Landlord, which request must contain the following inscription, in 14 point font and bold faced lettering:
“SECOND NOTICE DELIVERED PURSUANT TO PARAGRAPH 7.3 OF LEASE—FAILURE TO TIMELY RESPOND WITHIN FIVE (5) BUSINESS DAYS SHALL RESULT IN DEEMED APPROVAL OF ASSIGNMENT OR SUBLEASE.” If Tenant sends such a second request, and
Landlord fails to respond within five (5) business days after its receipt of same, the proposed assignment or subletting shall be deemed approved. Notwithstanding anything herein to the contrary, if Landlord exercises Landlord’s right to
terminate this Lease then Tenant may revoke Tenant’s request to transfer this Lease or a portion of the Leased Premises and thus end Landlord’s termination right by providing Landlord with written notice thereof within five
(5) business days after receipt of Landlord’s termination notice. 
 7.4 Conditions To Landlord’s
Consent. If Landlord elects to consent, or shall have been ordered to so consent by a court of competent jurisdiction, to such requested assignment or subletting, such consent shall be expressly conditioned upon the occurrence of each of the
conditions below set forth, and any purported assignment or subletting made or ordered prior to the full and complete satisfaction of each of the following conditions shall be void and, at the election of Landlord, which election may be exercised at
any time following such a purported assignment or subletting but prior to the satisfaction of each of the stated conditions, shall constitute a material default by Tenant under this Lease until cured by satisfying in full each such condition by the
assignee or sublessee. The conditions are as follows: 
 (a) Landlord having approved in form and substance the assignment
or sublease agreement and any ancillary documents, which approval shall not be unreasonably withheld by Landlord if the requirements of this Article 7 are otherwise complied with. 

(b) Each such sublessee or assignee having agreed, in writing satisfactory to Landlord and its counsel and for the benefit of
Landlord, to assume, to be bound by, and to perform the obligations of this Lease to be performed by Tenant which relate to space being subleased. 

(c) Tenant having fully and completely performed all of its obligations under the terms of this Lease through and including
the date of such assignment or subletting. 
 (d) Tenant having reimbursed to Landlord all reasonable costs and reasonable
attorneys’ fees incurred by Landlord in conjunction with the processing and documentation of any such requested subletting or assignment. Tenant shall be obligated to so reimburse Landlord whether or not such subletting or assignment is
completed. 
 (e) Tenant having delivered to Landlord a complete and fully-executed duplicate original of such sublease
agreement or assignment agreement (as applicable) and all related agreements. 
 (f) Tenant having paid, or having agreed in
writing to pay as to future payments, to Landlord fifty percent (50%) of all assignment consideration or excess rentals to be paid to Tenant or to any other on Tenant’s behalf or for Tenant’s benefit for such assignment or subletting
as follows: 
 (i) If Tenant assigns its interest under this Lease and if all or a portion of the consideration for such
assignment is to be paid by the assignee at the time of the assignment, that Tenant 

  
 24 

 Building D 
  

shall have paid to Landlord and Landlord shall have received an amount equal to fifty percent (50%) of the assignment consideration so paid or to be paid (whichever is the greater) at the
time of the assignment by the assignee; or 
 (ii) If Tenant assigns its interest under this Lease and if Tenant is to receive all or a
portion of the consideration for such assignment in future installments, that Tenant and Tenant’s assignee shall have entered into a written agreement with and for the benefit of Landlord satisfactory to Landlord and its counsel whereby Tenant
and Tenant’s assignee jointly agree to pay to Landlord an amount equal to fifty percent (50%) of all such future assignment consideration installments to be paid by such assignee as and when such assignment consideration is so paid; or

 (iii) If Tenant subleases the Leased Premises, that Tenant and Tenant’s sublessee shall have entered into a written agreement with
and for the benefit of Landlord satisfactory to Landlord and its counsel whereby Tenant and Tenant’s sublessee jointly agree to pay to Landlord fifty percent (50%) of all excess rentals to be paid by such sublessee. 

7.5 Assignment Consideration And Excess Rentals Defined. For purposes of this Article, including any amendment to this Article by way
of addendum or other writing: (i) the term “assignment consideration” shall mean all consideration to be paid by the assignee to Tenant or to any other party on Tenant’s behalf or for Tenant’s benefit as consideration
for such assignment, without deduction for any costs or expenses incurred by Tenant in connection with such assignment, except that Tenant may deduct third party, market rate leasing commissions and legal fees paid, and tenant improvement costs
incurred, in connection with the assignment, in which case the amount thereof may be deducted with the balance to be paid to Landlord, and (ii) the term “excess rentals” shall mean all consideration to be paid by the sublessee
to Tenant or to any other party on Tenant’s behalf or for Tenant’s benefit for the sublease of all or any part of the Leased Premises in excess of the rent due to Landlord under the terms of this Lease for the portion subleased for the
same period, without deduction for any costs or expenses incurred by Tenant in connection with such sublease, except that Tenant may deduct third party, market rate leasing commissions and legal fees paid, and tenant improvement costs incurred, in
connection with the sublease, in which case the amount thereof may be deducted with the balance to be paid to Landlord. Tenant agrees that the portion of any assignment consideration and/or excess rentals arising from any assignment or subletting by
Tenant which is to be paid to Landlord pursuant to this Article now is and shall then be the property of Landlord and not the property of Tenant. 

7.6 Payments. All payments required by this Article to be made to Landlord shall be made in cash in full as and when they become due.
At the time Tenant, Tenant’s assignee or sublessee makes each such payment to Landlord, Tenant or Tenant’s assignee or sublessee, as the case may be, shall deliver to Landlord an itemized statement in reasonable detail showing the method
by which the amount due Landlord was calculated and certified by the party making such payment as true and correct. 
 7.7 Good
Faith. The rights granted to Tenant by this Article are granted in consideration of Tenant’s express covenant, which Tenant hereby makes, that all pertinent allocations which are made by Tenant between the rental value of the Leased
Premises and the value of any of Tenant’s personal property which may be conveyed or leased (or services provided) generally concurrently with and which may reasonably be considered a part of the same transaction as the permitted assignment or
subletting shall be made fairly, honestly and in good faith. If Tenant shall breach this covenant, Landlord may immediately declare Tenant to be in default under the terms of this Lease and terminate this Lease and/or exercise any other rights and
remedies Landlord would have under the terms of this Lease in the case of a material default by Tenant under this Lease. 
 7.8 Effect Of
Landlord’s Consent. No subletting or assignment, even with the consent of Landlord, shall relieve Tenant of its personal and primary obligation to pay rent and to perform all of the other obligations to be performed by Tenant hereunder, and
Aruba Networks, Inc. hereby agrees as follows in connection with any assignment of this Lease: 
 (a) The liability of Aruba Networks, Inc.
under this Lease shall be primary, and in any right of action which shall accrue to Landlord under this Lease, Landlord may, at its option, proceed against Aruba Networks, Inc. without having commenced any action or obtained any judgment against an
assignee. Aruba Networks, Inc. further agrees that it may be joined in any action against an assignee in connection with the said obligations of assignee and recovery may be had against Aruba Networks, Inc. in any such action. Aruba Networks, Inc.
hereby expressly waives the benefits and defenses under California Civil Code Sections 2821, 2839, 2847, 2848, 2849 and 2855 to the fullest extent permitted by applicable law. 

(b) If an assignee is in default of its obligations under this Lease, Landlord may proceed against either Aruba Networks, Inc. or the
assignee, or both, or Landlord may enforce against Aruba Networks, Inc. or the assignee any rights that Landlord has under the Lease, in equity or under applicable law. If the Lease terminates due to an assignees default or bankruptcy or similar
debtor 

  
 25 

 Building D 
  

protection law, Landlord may enforce this Lease against Aruba Networks, Inc., even if Landlord would be unable to enforce it against the assignee. Aruba Networks, Inc. specifically agrees and
understands that Landlord may proceed forthwith and immediately against an assignee or against Aruba Networks, Inc. following any default by an assignee. Aruba Networks, Inc. hereby waives all benefits and defenses under California Civil Code
Sections 2845, 2848, 2849 and 2850, including without limitation: (i) the right to require Landlord to proceed against an assignee, proceed against or exhaust any security that Landlord holds from an assignee or pursue any other remedy in
Landlord’s power; (ii) any defense to its obligations hereunder based on the termination or limitation of an assignee’s liability; and (iii) all notices of the existence, creation, or incurring of new or additional obligations.
Landlord shall have the right to enforce this Lease regardless of the release or discharge of an assignee by Landlord or by operation of any law relating to protection of debtors, bankruptcy, assignments for the benefit of creditors, or insolvency.

 (c) The obligations of Aruba Networks, Inc. under this Lease shall remain in full force and effect and Aruba Networks, Inc. shall not be
discharged or limited by any of the following events with respect to an assignee or Aruba Networks, Inc.: (i) insolvency, bankruptcy, reorganization arrangement, adjustment, composition, assignment for the benefits of creditors, liquidation,
winding up or dissolution (each a “Financial Proceeding”); of (ii) any merger, acquisition, consolidation or change in entity structure, or any sale, lease, transfer, or other disposition of any entity’s assets, or any sale or
other transfer of interests in the entity (each an “Event of Reorganization”); or (iii) any sale, exchange, assignment, hypothecation or other transfer, in whole or in part, of Landlord’s interest in the Leased Premises or the
Lease. Without limiting the foregoing, Aruba Networks, Inc. hereby expressly waives the benefits and defenses under any statute or judicial decision (including but not limited to the case styled In Re Arden, 176 F. 3d 1226 (9th Cir. 1999)) that
would otherwise (i.e., were it not for such waiver) permit Aruba Networks, Inc. to claim or obtain the benefit of any so called “capped claim” available to an assignee in any Financial Proceeding. If all or any portion of the obligations
guaranteed hereunder are paid or performed and all or any part of such payment or performance is avoided or recovered, directly or indirectly, from Landlord as a preference, fraudulent transfer or otherwise, then Aruba Networks, Inc.’s
obligations hereunder shall continue and remain in full force and effect as to any such avoided or recovered payment or performance. 
 (d)
The provisions of this Lease may be changed by agreement between Landlord and an assignee without the consent of or notice to Aruba Networks, Inc. This Lease may be assigned by Landlord or an assignee, and the Leased Premises, or a portion thereof,
may be sublet by an assignee, all in accordance with the provisions of this Lease, without the consent of or notice to Aruba Networks, Inc. Aruba Networks, Inc. shall remain primarily liable for the performance of the Lease so assigned. Without
limiting the generality of the foregoing, Aruba Networks, Inc. waives the rights and benefits of California Civil Code Sections 2819 and 2820 with respect to any change to the Lease between Landlord and an assignee, and agrees that by doing so Aruba
Networks, Inc.’s liability shall continue even if (i) Landlord and an assignee alter any Lease obligations, or (ii) Aruba Networks, Inc.’s remedies or rights against an assignee are impaired or suspended without Aruba Networks,
Inc.’s consent by such alteration of Lease obligations. 
 Consent by Landlord to one or more assignments of Tenant’s interest in this Lease or to
one or more sublettings of the Leased Premises shall not be deemed to be a consent to any subsequent assignment or subletting. No subtenant shall have any right to assign its sublease or to further sublet any portion of the sublet premises or to
permit any portion of the sublet premises to be used or occupied by any other party. No sublease may be terminated or modified during any period that Tenant is in monetary or material non-monetary default under this Lease, without Landlord’s
prior written consent. If Landlord shall have been ordered by a court of competent jurisdiction to consent to a requested assignment or subletting, or such an assignment or subletting shall have been ordered by a court of competent jurisdiction over
the objection of Landlord, such assignment or subletting shall not be binding between the assignee (or sublessee) and Landlord until such time as all conditions set forth in Paragraph 7.4 above have been fully satisfied (to the extent not then
satisfied) by the assignee or sublessee, including, without limitation, the payment to Landlord of all agreed assignment considerations and/or excess rentals then due Landlord. 

7.9 Permitted Occupants. Notwithstanding any contrary provision of this Article 7, Tenant shall have the right, without the receipt of
Landlord’s consent and without payment to Landlord of any amounts under Paragraph 7.5 above, to permit the occupancy of up to thirty thousand (30,000) rentable square feet of space in the Leased Premises, in the aggregate, to any
individual(s) or entity (collectively, “Permitted Occupants”) that has an ongoing business relationship with Tenant (other than the dual occupancy of the Leased Premises), which occupancy shall include the use of a corresponding
interior support area and other portions of the Leased Premises and Common Areas (including the parking facilities and Fitness Center) which shall be common to Tenant and the Permitted Occupants, on and subject to the following conditions:
(i) each Permitted Occupant shall be of a character and reputation consistent with the quality of the Building and the Project; (ii) no Permitted Occupant shall occupy a separately demised portion of the Leased Premises or which contains
an entrance to such portion of the Leased Premises other than the primary entrance to the Leased Premises; (iii) such occupancy shall not be a subterfuge by Tenant to avoid its obligations under this Lease or the restrictions

  
 26 

 Building D 
  

on Transfers or allocation of excess Base Monthly Rent pursuant to this Article 7; (iv) Tenant shall not permit such use by any entity or organization in a manner such that the density of
use of any portion of the Leased Premises would materially and adversely increase the strain on the Building Systems beyond the manufacturer’s recommended specifications therefor or would violate any Laws, including but not limited to fire
codes; and (v) the Permitted Occupants shall obtain all permits and licenses required by Laws for occupying and use of the Leased Premises, if such permits and licenses are needed in addition to those held by Tenant; (vi) the Permitted
Occupants shall be subject to and subordinate to all of the terms and provisions of this Lease; and (vii) no such occupancy shall relieve Tenant from any liability under this Lease. Each Permitted Occupant shall be deemed to be a Tenant Party.
Tenant shall promptly supply Landlord with any documents or information reasonably requested by Landlord regarding the identity of any such Permitted Occupants. Any occupancy permitted under this Paragraph 7.9 shall not be deemed a transfer under
this Article 7. Notwithstanding the foregoing, no such occupancy shall relieve Tenant from any liability under this Lease. 
 ARTICLE 8

 LIMITATION ON LANDLORD’S LIABILITY AND INDEMNITY 

8.1 Limitation On Landlord’s Liability And Release. Landlord shall not be liable to Tenant for, and Tenant hereby releases
and waives all claims and rights of recovery against Landlord and its partners, principals, members, managers, officers, agents, employees, lenders, attorneys, contractors, invitees, consultants, predecessors, successors and assigns (including
without limitation prior and subsequent owners of the Property or the Project or portions thereof) (collectively, the “Landlord Indemnitees”) from, any and all liability, whether in contract, tort or on any other basis, for any
injury to or any damage sustained by Tenant or any of the Tenant Parties, any damage to property of Tenant or any of the Tenant Parties, or any loss to business, loss of profits or other financial loss of Tenant or any of the Tenant Parties
resulting from or attributable to the condition of, the management of, the repair or maintenance of, the protection of, the supply of services or utilities to, the damage in or destruction of the Leased Premises, the Building, the Property, the
Project, or the Common Areas, including without limitation (i) the failure, interruption, rationing or other curtailment or cessation in the supply of electricity, water, gas or other utility service to the Property, the Building or the Leased
Premises; (ii) the vandalism or forcible entry into the Building or the Leased Premises; (iii) the penetration of water into or onto any portion of the Leased Premises; (iv) the failure to provide security and/or adequate lighting in
or about the Property, the Building or the Leased Premises, (v) the existence of any design or construction defects within the Property, the Building or the Leased Premises; (vi) the failure of any mechanical systems to function properly
(such as the HVAC systems); (vii) the blockage of access to any portion of the Property, the Building or the Leased Premises, except that Tenant does not so release Landlord from such liability to the extent such damage was proximately caused
by Landlord’s gross negligence, willful misconduct, or Landlord’s failure to perform an obligation expressly undertaken by Landlord pursuant to this Lease after the time period(s) set forth in Paragraph 12.3 below shall have lapsed
following receipt of written notice from Tenant to so perform such obligation. 
 8.2 Tenant’s Indemnification Of
Landlord. Tenant shall defend with competent counsel reasonably satisfactory to Landlord any claims made or legal actions filed or threatened against the Landlord Indemnitees with respect to the violation of any Law, or the death, bodily
injury, personal injury, property damage, or interference with contractual or property rights suffered by any third party occurring within the Leased Premises or resulting from the use or occupancy by Tenant or any of the Tenant Parties of the
Leased Premises, the Building or the Common Areas, or resulting from the activities of Tenant or any of the Tenant Parties in or about the Leased Premises, the Building, the Common Areas, the Property, or the Project, and Tenant shall indemnify and
hold the Landlord Indemnitees harmless from any loss liability, penalties, or expense whatsoever (including but not limited to reasonable attorneys’ fees and any loss attributable to vacant space which otherwise would have been leased, but for
such activities) resulting therefrom, except to the extent proximately caused by the negligence or willful misconduct of Landlord. This indemnity agreement shall survive the expiration or sooner termination of this Lease. 

8.3 Landlord’s Indemnification Of Tenant. Landlord shall indemnify and hold Tenant harmless from any loss liability, penalties, or
expense whatsoever (including but not limited to reasonable attorneys’ fees) resulting from the gross negligence or willful misconduct of Landlord at or with respect to the Property, except to the extent proximately caused by the negligence or
willful misconduct of Tenant. This indemnity agreement shall survive the expiration or sooner termination of this Lease. 

  
 27 

 Building D 
  

ARTICLE 9 
 INSURANCE

 9.1 Tenant’s Insurance. Tenant shall maintain insurance complying with all of the following: 

(a) Tenant shall procure, pay for and keep in full force and effect, at all times during the Lease Term, the following: 

(i) Commercial general liability insurance insuring Tenant against liability for personal injury, bodily injury, death and damage to property
occurring within the Leased Premises, or resulting from Tenant’s use or occupancy of the Leased Premises, the Building, the Common Areas, the Property, or the Project, or resulting from Tenant’s activities in or about the Leased Premises,
the Property, or the Project, with coverage in an amount equal to Tenant’s Required Liability Coverage (as set forth in Article 1), which insurance shall contain “blanket contractual liability” and “broad form property
damage” endorsements insuring Tenant’s performance of Tenant’s obligations to indemnify Landlord as contained in this Lease. 

(ii) Fire and property damage insurance in “special form” coverage insuring Tenant against loss from physical damage to
Tenant’s personal property, inventory, trade fixtures and improvements within the Leased Premises with coverage for the full actual replacement cost thereof; 

(iii) Business income/extra expense insurance sufficient to pay Base Monthly Rent and Additional Rent for a period of not less than twelve
(12) months; 
 (iv) [Reserved]; 

(v) [Reserved]; 

(vi) [Reserved]; 
 (vii)
Workers’ compensation insurance (statutory coverage) with employer’s liability in amounts not less than $1,000,000 insurance sufficient to comply with all laws; and 

(viii) With respect to making of any alterations or modifications or the construction of improvements or the like undertaken by Tenant,
course of construction, commercial general liability, automobile liability and workers’ compensation (to be carried by Tenant’s contractor), in an amount and with coverage reasonably satisfactory to Landlord. 

(b) Each policy of liability insurance required to be carried by Tenant pursuant to this paragraph or actually carried by Tenant with respect
to the Leased Premises, the Property, or the Project: (i) shall, except with respect to insurance required by subparagraphs (a)(ii) and (a)(viii) above, name Landlord, and such Landlord affiliates as are designated by Landlord, as additional
insureds; (ii) [reserved]; (iii) shall be primary insurance providing that the insurer shall be liable for the full amount of the loss, up to and including the total amount of liability set forth in the declaration of coverage, without the
right of contribution from or prior payment by any other insurance coverage of Landlord; (iv) shall be carried with companies with Best’s ratings of at least A and XI; (v) shall provide that such policy shall not be subject to
cancellation, lapse or change except after at least thirty (30) days prior written notice to Landlord, and (vi) shall contain a so-called “severability” or “cross liability” endorsement. Each policy of property
insurance maintained by Tenant with respect to the Leased Premises, the Property, or the Project or any property therein (i) shall provide that such policy shall not be subject to cancellation except after at least thirty (30) days prior
written notice to Landlord and (ii) shall contain a waiver and/or a permission to waive by the insurer of any right of subrogation against Landlord, its partners, principals, members, managers, officers, employees, agents and contractors, which
might arise by reason of any payment under such policy or by reason of any act or omission of Landlord, its partners, principals, members, managers, officers, employees, agents and contractors. 

(c) Prior to the time Tenant or any of its contractors enters the Leased Premises, Tenant shall deliver to Landlord, with respect to each
policy of insurance required to be carried by Tenant pursuant to this Article, a certificate of the insurer certifying in form satisfactory to Landlord that a policy has been issued, premium paid, providing the coverage required by this Paragraph
and containing the provisions specified herein. With respect to each renewal or replacement of any such insurance, the requirements of this Paragraph must be complied with not less than thirty (30) days prior to the expiration or cancellation
of the policies being renewed or replaced. Landlord may, at any time and from time to time, inspect and/or copy any and all insurance policies required to be carried by Tenant pursuant to this Article. If Landlord’s Lender or insurance advisor
reasonably determines at any time that the amount of coverage set forth in Paragraph 9.1(a) for any policy of insurance Tenant is required to carry pursuant to this Article is not adequate, then Tenant shall increase the amount of coverage for such
insurance to such greater amount as Landlord’s Lender or insurance advisor reasonably deems adequate; provided, however, that Tenant shall not be required to increase such amount beyond (i) with respect to increases determined by
Landlord’s Lender, the amount(s) actually required by Landlord’s Lender, and (ii) with respect to increases determined by Landlord’s insurance advisor, the amount(s) then being required or carried by other prudent landlords in
the Santa Clara or Sunnyvale area. In the event Tenant does not maintain said insurance, Landlord may, in its sole discretion and without waiving any other remedies 

  
 28 

 Building D 
  

hereunder, send to Tenant written notice of such failure, and if such failure is not remedied within ten (10) days after receipt of such notice, then Landlord may procure said insurance and
Tenant shall pay to Landlord as additional rent the cost of said insurance plus a five percent (5%) administrative fee. 
 9.2
Landlord’s Insurance. With respect to insurance maintained by Landlord: 
 (a) Landlord shall maintain, as the minimum coverage
required of it by this Lease, fire and property damage insurance in so-called special form coverage insuring Landlord (and such others as Landlord may designate) against loss from physical damage to the Building with coverage of not less than one
hundred percent (100%) of the full actual replacement cost thereof and against loss of rents for a period of not less than six months. Such fire and property damage insurance, at Landlord’s election but without any requirements on
Landlord’s behalf to do so, (i) may be written in so-called “all risk” form, excluding only those perils commonly excluded from such coverage by Landlord’s then property damage insurer; (ii) may provide coverage for
physical damage to the improvements so insured for up to the entire full actual replacement cost thereof; (iii) may be endorsed to cover loss or damage caused by any additional perils against which Landlord may elect to insure, including
earthquake and/or flood; and/or (iv) may provide coverage for loss of rents for a period of up to twelve months. Landlord shall not be required to cause such insurance to cover any of Tenant’s personal property, inventory, and trade
fixtures, or any modifications, alterations or improvements made or constructed by Tenant to or within the Leased Premises. Landlord shall use commercially reasonable efforts to obtain such insurance at competitive rates. Any earthquake insurance
carried by Landlord for the Building or the Project may be a blanket insurance coverage policy covering the Project and other office buildings owned by Landlord or Landlord’s affiliates, and shall be a blanket policy during any period that
Landlord is a Menlo Equities affiliate and such a blanket policy is more economical than an individual earthquake policy. 
 (b) Landlord
shall maintain commercial general liability insurance insuring Landlord (and such others as are designated by Landlord) against liability for personal injury, bodily injury, death, and damage to property occurring in, on or about, or resulting from
the use or occupancy of the Property, or any portion thereof, with combined single limit coverage of at least Ten Million Dollars ($10,000,000). 

Landlord may carry such greater coverage as Landlord or Landlord’s Lender or insurance advisor may from time to time determine is
reasonably necessary for the adequate protection of Landlord, the Property, and the Project provided such insurance is commonly carried by owners of property similarly situated and operating under similar circumstances. 

(c) Landlord may maintain boiler and machinery insurance to limits sufficient to restore the Building. 

(d) Landlord may maintain any other insurance which in the opinion of its insurance advisor is prudent to carry under the given circumstances,
provided such insurance is commonly carried by owners of property similarly situated and operating under similar circumstances. 
 9.3
Mutual Waiver Of Subrogation. Landlord hereby releases Tenant, and Tenant hereby releases Landlord and its respective partners, principals, members, officers, agents, employees and servants, from any and all liability for loss, damage or injury
to the property of the other in or about the Leased Premises, the Property, or the Project which is caused by or results from a peril or event or happening which is covered by insurance actually carried and in force at the time of the loss by the
party sustaining such loss. 
 ARTICLE 10 

DAMAGE TO LEASED PREMISES 

10.1 Landlord’s Duty To Restore. If the Leased Premises, the Building or the Common Areas (including, without limitation, the
Fitness Center) are damaged by any peril after the Effective Date of this Lease, Landlord shall restore the same, as and when required by this paragraph, unless this Lease is terminated by Landlord pursuant to Paragraph 10.3 or by Tenant pursuant to
Paragraph 10.4. If this Lease is not so terminated, then upon the issuance of all necessary governmental permits, Landlord shall commence and diligently prosecute to completion the restoration of the Leased Premises, the Building or the Common Area,
as the case may be, to the extent then allowed by law, to substantially the same condition in which it existed as of the Lease Commencement Date. Landlord’s obligation to restore shall be limited to the improvements constructed by Landlord.
Landlord shall have no obligation to restore any alterations, modifications or improvements made by Tenant to the Leased Premises or any of Tenant’s personal property, inventory or trade fixtures. Upon completion of the restoration by Landlord,
Tenant shall forthwith replace or fully repair all of the Tenant Improvements to like or similar conditions as existed at the time immediately prior to such damage or destruction. 

10.2 Insurance Proceeds. All insurance proceeds available from the fire and property damage insurance carried by Landlord shall be paid
to and become the property of Landlord. If this Lease is terminated pursuant to either Paragraph 10.3 or 10.4, all insurance proceeds available from 

  
 29 

 Building D 
  

insurance carried by Tenant which cover loss of Tenant’s Alterations shall be paid to and become the property of Tenant. With respect to insurance proceeds payable under Tenant’s
insurance policies for damage or destruction to the Tenant Improvements, Landlord and Tenant shall share such proceeds in accordance with their relative contributions to the initial cost thereof. For example, if the Tenant Improvements were to cost
a total of $130 per rentable square foot, and Landlord were to have contributed a total of $65 per rentable square foot on the Tenant Improvements, then Landlord and Tenant would share such proceeds equally. The determination of Landlord’s
property and Tenant’s property shall be made pursuant to Paragraph 6.2. 
 10.3 Landlord’s Right To Terminate. Landlord
shall have the option to terminate this Lease in the event any of the following occurs, which option may be exercised only by delivery to Tenant of a written notice of election to terminate within thirty (30) days after the date of such damage
or destruction: 
 (a) The Building is damaged by any peril covered by valid and collectible insurance actually carried by Landlord and in
force at the time of such damage or destruction (or any insurance Landlord was required to carry pursuant to the terms of this Lease) to such an extent that the estimated cost to restore the Building exceeds the lesser of (i) the insurance
proceeds available from insurance actually carried by Landlord, or (ii) fifty percent of the then actual replacement cost thereof. Notwithstanding the foregoing, Tenant may override Landlord’s election to terminate the Lease pursuant to
clause (i) above if Tenant shall agree in writing within ten (10) days after receipt of Landlord’s notice electing to terminate this Lease to pay any costs of restoration to the extent such costs exceed the amount of any insurance
proceeds received by Landlord (the “Casualty Shortfall Amount”), in which event Landlord cannot terminate this Lease and must rebuild the areas affected by the Casualty; provided, however, that if Tenant exercises such election,
Tenant shall enter into an agreement with Landlord pursuant to which Tenant will covenant to deposit into an escrow or, to the extent required by any lender with a lien on the Leased Premises, with such lender the Casualty Shortfall Amount on terms
and conditions reasonably acceptable to Landlord. In addition, if Tenant elects to override Landlord’s election to terminate this Lease as provided above, Tenant shall execute and deliver to any such lender any documents reasonably required by
such lender to evidence Tenant’s intention to keep this Lease in full force and effect. 
 (b) The Building is damaged by an uninsured
peril, which peril Landlord was not required to, and did not, insure against pursuant to the provisions of Article 9 of this Lease. 
 (c)
The Building is damaged by any peril and, because of the Laws or Restrictions then in force, the Building, if restored, cannot be used for the same use being made thereof before such damage. 

Notwithstanding anything herein to the contrary, if the Leased Premises is not affected by the casualty in question, then Landlord may not terminate this
Lease unless it terminates the leases of all of the other tenants of the Building. 
 10.4 Tenant’s Right To Terminate. If the
Leased Premises, the Building or the Common Area are damaged by any peril and Landlord does not elect to terminate this Lease or is not entitled to terminate this Lease pursuant to this Article, then as soon as reasonably practicable, Landlord shall
furnish Tenant with the written opinion of Landlord’s architect or construction consultant as to when the restoration work required of Landlord may be complete. Landlord agrees to provide such opinion to Tenant within thirty (30) days
after the date of damage if reasonably practicable; otherwise, Landlord will provide a written status report to Tenant within such 30-day period and shall subsequently issue a final opinion to Tenant within ten (10) days of the date on which
Landlord determines the availability of permits to rebuild and the date on which Landlord determines the availability of insurance proceeds to rebuild, whichever is later. Will Tenant shall have the option to terminate this Lease (if Tenant is not
then in monetary or material non-monetary default) in the event any of the following occurs, which option may be exercised only by delivery to Landlord of a written notice of election to terminate within thirty (30) days after Tenant receives
from Landlord the estimate of the time needed to complete such restoration: 
 (a) If the time estimated to substantially complete the
restoration exceeds twelve months from and after the date the architect’s or construction consultant’s written opinion is delivered; or 

(b) If the damage occurred within eighteen months of the last day of the Lease Term and the time estimated to substantially complete the
restoration exceeds one hundred eighty (180) days from and after the date such restoration is commenced. 
 (c) In addition, if the
damage was not caused by the actions or omissions of Tenant or any of Tenant’s Parties, Tenant may terminate this Lease if the Leased Premises or any portions of the Common Area providing access to or parking for the Leased Premises are damaged
by a casualty to the extent that Tenant does not have reasonable access to or parking for the Leased Premises and Landlord 

  
 30 

 Building D 
  

has not within a reasonable time (not to exceed ninety (90) days from the date of the casualty) provided a reasonable parking alternative for Tenant at the Project or in offsite areas within
reasonable proximity to the Building and Tenant is not actually using the Leased Premises as a result thereof. 
 10.5 Tenant’s
Waiver. Landlord and Tenant agree that the provisions of Paragraph 10.4 above, captioned “Tenant’s Right To Terminate”, are intended to supersede and replace the provisions contained in California Civil Code, Section 1932,
Subdivision 2, and California Civil Code, Section 1933, and accordingly, Tenant hereby waives the provisions of such Civil Code Sections and the provisions of any successor Civil Code Sections or similar laws hereinafter enacted. 

10.6 Abatement Of Rent. In the event of damage to the Leased Premises which does not result in the termination of this Lease, then the
Base Monthly Rent (and any Additional Rent) shall be temporarily abated during the period of Landlord’s and/or Tenant’s (as applicable) restoration, in proportion in the degree to which Tenant’s use of the Leased Premises during the
restoration period is impaired by such damage. In addition, if such casualty shall have damaged the Building or any portion of the Common Area providing access to or parking for the Leased Premises are damaged by casualty to the extent that Tenant
does not have reasonable access to or parking for the Leased Premises and Landlord has not within a reasonable time (not to exceed ninety (90) days from the date of casualty) provided a reasonable parking alternative for Tenant at the Project
or within reasonable proximity to the Building, then Landlord shall allow Tenant a proportionate abatement of Base Monthly Rent and Property Operating Expenses during the time and to the extent the Leased Premises are unfit for occupancy for the
purposes permitted under this Lease, or any portions of the Common Area providing access to or parking for the Leased Premises are damaged by Casualty to the extent that Tenant does not have reasonable access to or parking for the Leased Premises,
and in any of those events the Leased Premises are not occupied by Tenant as a result thereof. If a casualty: (i) shall have damaged the parking facilities so that Tenant does not have reasonable access to or parking for the Leased Premises,
then, subject to Laws, Restrictions and the rights of other tenants, Landlord shall use good faith efforts to explore reasonable parking alternatives for Tenant at the Project or in offsite areas within reasonable proximity to the Building, and, in
such event, Landlord shall be responsible for the costs of providing a shuttle to and from such offsite Parking and the Building, provided that nothing herein shall be deemed to create any obligation of Landlord to incur significant expense or
liability in doing so, (ii) shall have damaged the Fitness Center, then, subject to Laws, Restrictions and the rights of other tenants, Tenant shall have no obligation to pay any Property Operating Expenses associated with such facilities, and
Landlord shall reasonably cooperate with Tenant to explore options for Tenant’s employees exercise elsewhere in the Project, until such facilities are rebuilt, and/or (iii) shall have damaged a portion of the Common Areas necessary for
Tenant’s access to the Building, then, subject to Laws, Restrictions and the rights of other tenants, Landlord shall use good faith efforts to explore reasonable alternative means of access to the Building at the Project with Tenant, provided
that nothing herein shall be deemed to create any obligation of Landlord to incur significant expense or liability in doing so. 
 ARTICLE
11 
 CONDEMNATION 

11.1 Tenant’s Right To Terminate. Except as otherwise provided in Paragraph 11.4 below regarding temporary takings, Tenant shall
have the option to terminate this Lease if, as a result of any taking, (i) all of the Leased Premises is taken, or (ii) twenty-five percent (25%) or more of the Leased Premises is taken and the part of the Leased Premises that remains
cannot, within a reasonable period of time, be made reasonably suitable for the continued operation of Tenant’s business. Tenant must exercise such option within a reasonable period of time, to be effective on the later to occur of (i) the
date that possession of that portion of the Leased Premises that is condemned is taken by the condemnor or (ii) the date Tenant vacated the Leased Premises. 

11.2 Landlord’s Right To Terminate. Except as otherwise provided in Paragraph 11.4 below regarding temporary takings, Landlord
shall have the option to terminate this Lease if, as a result of any taking, (i) all of the Leased Premises is taken, (ii) twenty-five percent (25%) or more of the Leased Premises is taken and the part of the Leased Premises that
remains cannot, within a reasonable period of time, be made reasonably suitable for the continued operation of Tenant’s business, or (iii) because of the Laws or Restrictions then in force, the Leased Premises may not be used for the same
use being made before such taking, whether or not restored as required by Paragraph 11.3 below. Any such option to terminate by Landlord must be exercised within a reasonable period of time, to be effective as of the date possession is taken by the
condemnor. 
 11.3 Restoration. If any part of the Leased Premises or the Building is taken and this Lease is not terminated, then
Landlord shall, to the extent not prohibited by Laws or Restrictions then in force, repair any damage occasioned thereby to the remainder thereof to a condition reasonably suitable for Tenant’s continued operations and otherwise, to the extent
practicable, in the manner and to the extent provided in Paragraph 10.1. 

  
 31 

 Building D 
  

11.4 Temporary Taking. If a material portion of the Leased Premises is temporarily taken for a period of one year or less and such
period does not extend beyond the Lease Expiration Date, this Lease shall remain in effect. If any material portion of the Leased Premises is temporarily taken for a period which exceeds one year or which extends beyond the Lease Expiration Date,
then the rights of Landlord and Tenant shall be determined in accordance with Paragraphs 11.1 and 11.2 above. 
 11.5 Division Of
Condemnation Award. Any award made for any taking of the Property, the Building, or the Leased Premises, or any portion thereof, shall belong to and be paid to Landlord, and Tenant hereby assigns to Landlord all of its right, title and interest
in any such award; provided, however, that Tenant shall be entitled to receive any portion of the award that is made specifically (i) for the taking of personal property, inventory or trade fixtures belonging to Tenant, (ii) for the
interruption of Tenant’s business or its moving costs, or (iii) for the value of any leasehold improvements installed and paid for by Tenant. The rights of Landlord and Tenant regarding any condemnation shall be determined as provided in
this Article, and each party hereby waives the provisions of Section 1265.130 of the California Code of Civil Procedure, and the provisions of any similar law hereinafter enacted, allowing either party to petition the Supreme Court to terminate
this Lease and/or otherwise allocate condemnation awards between Landlord and Tenant in the event of a taking of the Leased Premises. 

11.6 Abatement Of Rent. In the event of a taking of the Leased Premises which does not result in a termination of this Lease (other
than a temporary taking), then, as of the date possession is taken by the condemning authority, the Base Monthly Rent shall be reduced in the same proportion that the area of that part of the Leased Premises so taken (less any addition to the area
of the Leased Premises by reason of any reconstruction) bears to the area of the Leased Premises immediately prior to such taking. 

11.7 Taking Defined. The term “taking” or “taken” as used in this Article 11 shall mean any transfer
or conveyance of all or any portion of the Property or the Project to a public or quasi-public agency or other entity having the power of eminent domain pursuant to or as a result of the exercise of such power by such an agency, including any
inverse condemnation and/or any sale or transfer by Landlord of all or any portion of the Property or the Project to such an agency under threat of condemnation or the exercise of such power. 

ARTICLE 12 
 DEFAULT AND
REMEDIES 
 12.1 Events Of Tenant’s Default. Tenant shall be in default of its obligations under this Lease if any of the
following events occur: 
 (a) Tenant shall have failed to pay Base Monthly Rent or any Additional Rent when due; provided that Tenant shall
be entitled to receive written notice of late payment one time during each year of the Lease Term, and with respect to that one late payment, Tenant shall not be in default under this Paragraph 12.1(a) unless Tenant has failed to make the required
payment within three (3) days after such notice from Landlord. After the notice has been given, Landlord shall not be required to provide any further notices to Tenant; or 

(b) Tenant shall have done or permitted to be done any act, use or thing in its use, occupancy or possession of the Leased Premises or the
Building or Common Areas which is prohibited by the terms of this Lease or Tenant shall have failed to perform any term, covenant, or condition of this Lease (except those requiring the payment of Base Monthly Rent or Additional Rent, which failures
shall be governed by subparagraph (a) above) and such default is not cured within the shorter of (i) any specific time period expressly provided under this Lease for the performance of such term, covenant or condition, or (ii) thirty
(30) days after written notice from Landlord to Tenant specifying the nature of such default and requesting Tenant to cure the same, or within such longer period as is reasonably required in the event such default is curable but not within such
thirty (30) day period, provided such cure is promptly commenced within such thirty (30) day period and is thereafter diligently prosecuted to completion; or 

(c) (i) Tenant shall have sublet the Leased Premises or assigned or encumbered its interest in this Lease in violation of the provisions
contained in Article 7, or (ii) any guarantor shall have assigned or delegated its rights or obligations under the applicable guaranty without first obtaining Landlord’s written consent if and as required by the terms of the applicable
guaranty, in either case (i) or (ii), whether voluntarily or by operation of law; or 
 (d) Tenant shall have abandoned the Leased
Premises (as opposed to having vacated the same in accordance with Paragraph 4.1 above); or 
 (e) Tenant or any guarantor of this Lease
shall have permitted or suffered the sequestration or attachment of, or execution on, or the appointment of a custodian or receiver with respect to, all or any substantial part of the property or assets of Tenant (or such guarantor) or any property
or 

  
 32 

 Building D 
  

asset essential to the conduct of Tenant’s (or such guarantor’s) business, and Tenant (or such guarantor) shall have failed to obtain a return or release of the same within thirty
(30) days thereafter, or prior to sale pursuant to such sequestration, attachment or levy, whichever is earlier; or 
 (f) Tenant or
any guarantor of this Lease shall have made a general assignment of all or a substantial part of its assets for the benefit of its creditors; or 

(g) Tenant or any guarantor of this Lease shall have allowed (or sought) to have entered against it a decree or order which: (i) grants
or constitutes an order for relief, appointment of a trustee, or condemnation or a reorganization plan under the bankruptcy laws of the United States; (ii) approves as properly filed a petition seeking liquidation or reorganization under said
bankruptcy laws or any other debtor’s relief law or similar statute of the United States or any state thereof; or (iii) otherwise directs the winding up or liquidation of Tenant; provided, however, if any decree or order was entered
without Tenant’s consent or over Tenant’s objection, Landlord may not terminate this Lease pursuant to this Subparagraph if such decree or order is rescinded or reversed within ninety (90) days after its original entry; or 

(h) Tenant or any guarantor of this Lease shall have availed itself of the protection of any debtor’s relief law, moratorium law or other
similar law which does not require the prior entry of a decree or order. 
 (i) If during any period that Landlord (or its affiliate) and
Tenant (or its affiliate) are the landlord and tenant, respectively, under the Building C Lease, Tenant (or its affiliate) shall be in default of its obligations under the Building C Lease. Landlord shall have the right, acting alone, to elect from
time to time to delete and/or reinstate, as applicable, this subparagraph (i) and Paragraph 12.3(b) below by notice to Tenant delivered in accordance with Paragraph 13.10 below. If at any time Landlord makes such election, then Tenant agrees,
at Landlord’s request, to execute an amendment to this Lease the effect of which is to delete or reinstate, as applicable, this subparagraph (i) and Paragraph 12.3(b) below, and in the event of a deletion, to retain the reinstatement
right. 
 12.2 Landlord’s Remedies. In the event of any default by Tenant, and without limiting Landlord’s right to
indemnification as provided in Article 8.2, Landlord shall have the following remedies, in addition to all other rights and remedies provided by law or otherwise provided in this Lease, to which Landlord may resort cumulatively, or in the
alternative: 
 (a) Landlord may, at Landlord’s election, keep this Lease in effect and enforce, by an action at law or in equity, all
of its rights and remedies under this Lease including, without limitation, (i) the right to recover the rent and other sums as they become due by appropriate legal action, (ii) the right to make payments required by Tenant, or perform
Tenant’s obligations and be reimbursed by Tenant for the cost thereof with interest at a rate equal to the Default Interest Rate from the date the sum is paid by Landlord until Landlord is reimbursed by Tenant, and (iii) the remedies of
injunctive relief and specific performance to prevent Tenant from violating the terms of this Lease and/or to compel Tenant to perform its obligations under this Lease, as the case may be. 

(b) Landlord may, at Landlord’s election, terminate this Lease by giving Tenant written notice of termination, in which event this Lease
shall terminate on the date set forth for termination in such notice, in which event Tenant shall immediately surrender the Leased Premises to Landlord, and if Tenant fails to do so, Landlord may, without prejudice to any other remedy which it may
have for possession or arrearages in rent, enter upon and take possession of the Leased Premises and expel or remove Tenant and any other person who may be occupying the Leased Premises or any part thereof, without being liable for prosecution or
any claim for damages therefor. Any termination under this subparagraph shall not relieve Tenant from its obligation to pay to Landlord all Base Monthly Rent and Additional Rent then or thereafter due, or any other sums due or thereafter accruing to
Landlord, or from any claim against Tenant for damages previously accrued or then or thereafter accruing. In no event shall any one or more of the following actions by Landlord, in the absence of a written election by Landlord to terminate this
Lease constitute a termination of this Lease: 
 (i) Appointment of a receiver or keeper in order to protect Landlord’s interest
hereunder; 
 (ii) Consent to any subletting of the Leased Premises or assignment of this Lease by Tenant, whether pursuant to the
provisions hereof or otherwise; or 
 (iii) Any action taken by Landlord or its partners, principals, members, officers, agents, employees,
or servants, which is intended to mitigate the adverse effects of any breach of this Lease by Tenant, including, without limitation, any action taken to maintain and preserve the Leased Premises on any action taken to relet the Leased Premises or
any portion thereof for the account at Tenant and in the name of Tenant. 

  
 33 

 Building D 
  

(c) In the event Tenant breaches this Lease and abandons the Leased Premises, Landlord may terminate this Lease, but this Lease shall not
terminate unless Landlord gives Tenant written notice of termination. If Landlord does not terminate this Lease by giving written notice of termination, Landlord may enforce all its rights and remedies under this Lease, including the right and
remedies provided by California Civil Code Section 1951.4 (“lessor may continue lease in effect after lessee’s breach and abandonment and recover rent as it becomes due, if lessee has right to sublet or assign, subject only to
reasonable limitations”), as in effect on the Effective Date of this Lease. 
 (d) In the event Landlord terminates this Lease,
Landlord shall be entitled, at Landlord’s election, to the rights and remedies provided in California Civil Code Section 1951.2, as in effect on the Effective Date of this Lease. For purposes of computing damages pursuant to
Section 1951.2, an interest rate equal to the Default Interest Rate shall be used. Such damages shall include, without limitation: 

(i) The worth at the time of the award of the unpaid rent which had been earned at the time of termination; plus 

(ii) The worth at the time of award of the amount by which the unpaid rent which would have been earned after termination until the time of
award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus 
 (iii) The worth at the time of
award of the amount by which the unpaid rent for the balance of the term after the time of award exceeds the amount of such rental loss that Tenant proves could be reasonably avoided, computed by discounting such amount at the discount rate of the
Federal Reserve Bank of San Francisco, at the time of award plus one percent; plus 
 (iv) Any other amount necessary to compensate
Landlord for all detriment proximately caused by Tenant’s failure to perform Tenant’s obligations under this Lease, or which in the ordinary course of things would be likely to result therefrom, including without limitation, the following:
(i) expenses for cleaning, repairing or restoring the Leased Premises, (ii) expenses for altering, remodeling or otherwise improving the Leased Premises for the purpose of reletting, including removal of existing leasehold improvements
and/or installation of additional leasehold improvements (regardless of how the same is funded, including reduction of rent, a direct payment or allowance to a new tenant, or otherwise), (iii) broker’s fees allocable to the remainder of
the term of this Lease, advertising costs and other expenses of reletting the Leased Premises; (iv) costs of carrying and maintaining the Leased Premises, such as taxes, insurance premiums, utility charges and security precautions (although the
foregoing shall not in any way modify Paragraph 5.3 above), (v) expenses incurred in removing, disposing of and/or storing any of Tenant’s personal property, inventory or trade fixtures remaining therein; (vi) reasonable
attorney’s fees, expert witness fees, court costs and other reasonable expenses incurred by Landlord (but not limited to taxable costs) in retaking possession of the Leased Premises, establishing damages hereunder, and releasing the Leased
Premises; and (vii) any other expenses, costs or damages otherwise incurred or suffered as a result of Tenant’s default. 
 (e)
Pursuant to California Code of Civil Procedure Section 1161.1, Landlord may accept a partial payment of Rent after serving a notice pursuant to California Code of Civil Procedure Section 1161, and may without further notice to the Tenant,
commence and pursue an action to recover the difference between the amount demanded in that notice and the payment actually received. This acceptance of such a partial payment of Rent does not constitute a waiver of any rights, including any right
the Landlord may have to recover possession of the Leased Premises. Further, Tenant agrees that any notice given by Landlord pursuant to Paragraph 12.1 of the Lease shall satisfy the requirements for notice under California Code of Civil Procedure
Section 1161, and Landlord shall not be required to give any additional notice in order to be entitled to commence an unlawful detainer proceeding. 

12.3 Landlord’s Default And Tenant’s Remedies. 

(a) In the event Landlord fails to perform its obligations under this Lease, Landlord shall nevertheless not be in default under the terms of
this Lease until such time as Tenant shall have first given Landlord written notice specifying the nature of such failure to perform its obligations, and then only after Landlord shall have had thirty (30) days following its receipt of such
notice within which to perform such obligations; provided that, if longer than thirty (30) days is reasonably required in order to perform such obligations, Landlord shall have such longer period. In the event of Landlord’s default as
above set forth, then, and only then, Tenant may then proceed in equity or at law to compel Landlord to perform its obligations and/or to recover damages proximately caused by such failure to perform (except as and to the extent Tenant has waived
its right to damages as provided in this Lease). 
 (b) Subparagraph (a) above shall also be applicable if Landlord (or its affiliate)
and Tenant (or its affiliate) are the landlord and tenant, respectively, under the Building C Lease and Landlord (or its affiliate) is in default of its obligations under the Building C Lease. This subparagraph (b) shall

  
 34 

 Building D 
  

automatically terminate and be void and of no force or effect at any time that either (i) Landlord (or its affiliate) is not the landlord
under the Building C Lease, or (ii) Paragraph 12.1(i) above has been deleted pursuant to and in accordance with such Paragraph 12.1(i); provided, however, that if at any time Paragraph 12.1(i) is reinstated pursuant to and in
accordance with such Paragraph 12.1(i), then this subparagraph (b) shall be reinstated as well. 
 12.4 Limitation Of Tenant’s
Recourse. Tenant’s sole recourse against Landlord shall be to Landlord’s interest in the Project and the revenues, insurance proceeds and condemnation awards therefrom; provided, however, that in no event shall Tenant have recourse to
any sums distributed to Landlord’s members or manager(s) in the ordinary course of business (including but not limited to sale or refinancing proceeds distributed upon a sale or refinancing, as applicable). If Landlord is a corporation, trust,
partnership, joint venture, limited liability company, unincorporated association, or other form of business entity, Tenant agrees that (i) the obligations of Landlord under this Lease shall not constitute personal obligations of the officers,
directors, trustees, partners, joint venturers, members, managers, owners, stockholders, or other principals of such business entity, and (ii) Tenant shall have recourse only to the interest of such corporation, trust, partnership, joint
venture, limited liability company, unincorporated association, or other form of business entity in the Building and the Common Areas for the satisfaction of such obligations and not against the assets of such officers, directors, trustees,
partners, joint venturers, members, managers, owners, stockholders or principals. Additionally, if Landlord is a partnership or limited liability company, then Tenant covenants and agrees: 

(a) No partner, manager, or member of Landlord shall be sued or named as a party in any suit or action brought by Tenant with respect to any
alleged breach of this Lease (except to the extent necessary to secure jurisdiction over the partnership or limited liability company and then only for that sole purpose); 

(b) No service of process shall be made against any partner, manager, or member of Landlord except for the sole purpose of securing
jurisdiction over the partnership; and 
 (c) No writ of execution will ever be levied against the assets of any partner, manager, or member
of Landlord other than to the extent of his or her interest in the assets of the partnership or limited liability company constituting Landlord. 
 Tenant
further agrees that each of the foregoing covenants and agreements shall be enforceable by Landlord and by any partner or manager or member of Landlord and shall be applicable to any actual or alleged misrepresentation or nondisclosure made
regarding this Lease or the Leased Premises or any actual or alleged failure, default or breach of any covenant or agreement either expressly or implicitly contained in this Lease or imposed by statute or at common law. 

12.5 Limitation Of Tenant’s Recourse. Notwithstanding any provision of this Lease to the contrary, Tenant shall not be liable to
Landlord for consequential or special damages, except that this sentence (i) shall not limit the indemnification obligations of Tenant hereunder with respect to third party claims, (ii) shall not apply to claims for the breach by Tenant of
Tenant’s obligations under Paragraph 4.11, (iii) shall not limit Landlord’s right to recover from Tenant, (a) damages for Tenant’s breach of this Lease as described in Paragraph 12.2 above, to the extent recoverable from
Tenant under applicable Laws, or (b) consequential damages if Tenant holds over after the Lease Expiration Date or prior termination of this Lease, provided that Landlord delivers to Tenant a Vacation Notice as and when required by Paragraph
13.2. 
 12.6 Tenant’s Waiver. Landlord and Tenant agree that the provisions of Paragraph 12.3 above are intended to supersede
and replace the provisions of California Civil Code Sections 1932(1), 1941 and 1942, and accordingly, Tenant hereby waives the provisions of California Civil Code Sections 1932(1), 1941 and 1942 and/or any similar or successor law regarding
Tenant’s right to terminate this Lease or to make repairs and deduct the expenses of such repairs from the rent due under this Lease. 

ARTICLE 13 
 GENERAL
PROVISIONS 
 13.1 Taxes On Tenant’s Property. Tenant shall pay before delinquency any and all taxes, assessments, license
fees, use fees, permit fees and public charges of whatever nature or description levied, assessed or imposed against Tenant or Landlord by a governmental agency arising out of, caused by reason of or based upon Tenant’s estate in this Lease,
Tenant’s ownership of property, improvements made by Tenant to the Leased Premises or the Common Areas, improvements made by Landlord for Tenant’s use within the Leased Premises or the Common Areas, Tenant’s use (or estimated use) of
public facilities or services or Tenant’s consumption (or estimated consumption) of public utilities, energy, water or other resources (collectively, “Tenant’s Interest”). Upon demand by Landlord, Tenant shall furnish
Landlord with satisfactory evidence of these payments. If any such taxes, assessments, fees or public charges are levied against Landlord, Landlord’s property, the Building, the Property, or the Project, or if 

  
 35 

 Building D 
  

the assessed value of the Building, the Property, or the Project is increased by the inclusion therein of a value placed upon Tenant’s
Interest, regardless of the validity thereof, Landlord shall have the right to require Tenant to pay such taxes, and if not paid and satisfactory evidence of payment delivered to Landlord at least ten (10) days prior to delinquency, then
Landlord shall have the right to pay such taxes on Tenant’s behalf and to invoice Tenant for the same, in either case whether before or after the expiration or earlier termination of the Lease Term. Tenant shall, within the earlier to occur of
(a) thirty (30) days of the date it receives an invoice from Landlord setting forth the amount of such taxes, assessments, fees, or public charge so levied, or (b) the due date of such invoice, pay to Landlord, as Additional Rent, the
amount set forth in such invoice. Failure by Tenant to pay the amount so invoiced within such time period shall be conclusively deemed a default by Tenant under this Lease. Tenant shall have the right to bring suit in any court of competent
jurisdiction to recover from the taxing authority the amount of any such taxes, assessments, fees or public charges so paid. 
 13.2
Holding Over. This Lease shall terminate without further notice on the Lease Expiration Date (as set forth in Article 1). Any holding over by Tenant after expiration of the Lease Term shall neither constitute a renewal nor extension of this
Lease nor give Tenant any rights in or to the Leased Premises except as expressly provided in this Paragraph. Any such holding over to which Landlord has consented shall be construed to be a tenancy from month to month, on the same terms and
conditions herein specified insofar as applicable, except that the Base Monthly Rent shall be increased to an amount equal to one hundred twenty-five percent (125%) of the Monthly Base Rent for the last month immediately preceding such holding
over for the first two (2) months or any such holding over, and thereafter one hundred fifty percent (150%) of the Base Monthly Rent payable during the last full month immediately preceding such holding over. Without limiting the
foregoing, in the event of a holding over to which Landlord has consented, any rights of Landlord or obligations of Tenant set forth in this Lease and purporting to apply during the term of this Lease, shall nonetheless also be deemed to apply
during any such hold over period. Tenant acknowledges that if Tenant holds over without Landlord’s consent, such holding over may compromise or otherwise affect Landlord’s ability to enter into new leases with prospective tenants regarding
the Leased Premises. 
 Therefore, in the event Tenant does not vacate the Leased Premises in accordance with the terms of this Paragraph
13.2 on or before the expiration of the Lease Term (or the expiration of a holdover term, if applicable) after receiving at least thirty (30) days’ advance written notice from Landlord demanding that Tenant vacate the Leased Premises and
otherwise satisfying the requirements set forth below (a “Vacation Notice”), which notice may be given to Tenant at any time during the last sixty (60) days of the Lease Term or during any holdover period, Tenant shall be
liable for all damages (including attorneys’ fees and expenses) of whatever type (including consequential damages) incurred by Landlord as a result of such holding over, and Tenant shall protect, defend, indemnify and hold Landlord harmless
from and against all claims resulting from such failure to vacate, including, without limiting the foregoing, any claims made by any succeeding tenant founded upon such failure to surrender, and any losses suffered by Landlord, including lost
profits, resulting from such failure to surrender. The Vacation Notice shall specifically refer to this Lease and the address of the Building, and shall include (on the first page of the Vacation Notice) the following language in bold, capitalized
font: “NOTICE: UNDER PARAGRAPH 13.2 OF THE LEASE, TENANT’S FAILURE TO VACATE THE LEASED PREMISES BY THE EXPIRATION OR EARLIER TERMINATION OF THE LEASE TERM (OR HOLDOVER TERM IF APPLICABLE) MAY RESULT IN SIGNIFICANT DAMAGES TO
LANDLORD, INCLUDING CONSEQUENTIAL DAMAGES.” 
 13.3 Subordination To Mortgages. This Lease is subject to and subordinate to
all ground leases, mortgages and deeds of trust which affect the Building, the Property, or the Project and which are of public record as of the Effective Date of this Lease, and to all renewals, modifications, consolidations, replacements and
extensions thereof. Notwithstanding the foregoing, if requested by Landlord, Tenant agrees, within ten (10) days after Landlord’s written request therefor, to execute, acknowledge and deliver to Landlord any and all documents or
instruments reasonably requested by Landlord or by the existing lessor or lender to assure the subordination of this Lease to such ground lease, mortgage or deed of trust, including but not limited to a subordination agreement in the form attached
to this Lease as Exhibit I or such other customary form as any such lessor or lender may require (an “SNDA”). If the form of SNDA is different than the form attached to this Lease as Exhibit I, then Tenant shall have the
right to make reasonable comments to such form provided that Tenant shall not be entitled to object to any provision of such SNDA which is substantially the same as a provision set forth in Exhibit I. If the lessor under any such ground lease or any
lender holding any such mortgage or deed of trust shall advise Landlord that it desires or requires this Lease to be made prior and superior thereto, then, upon written request of Landlord to Tenant, Tenant shall promptly execute, acknowledge and
deliver any and all customary or reasonable documents or instruments which Landlord and such lessor or lender deems necessary or desirable to make this Lease prior thereto, subject to Tenant’s right to make reasonable comments to such documents
or instruments (provided that Tenant shall not be entitled to object to any provision of such documents or instruments which is substantially the same as a provision set forth in Exhibit I). Tenant hereby consents to Landlord’s ground leasing
the land underlying the Building, the Property, or the Project and/or encumbering the Building, the Property, or the Project as security for future loans on such 

  
 36 

 Building D 
  

terms as Landlord shall desire, all of which future ground leases, mortgages or deeds of trust shall be subject to and subordinate to this Lease. However, if any lessor under any such future
ground lease or any lender holding such future mortgage or deed of trust shall desire or require that this Lease be made subject to and subordinate to such future ground lease, mortgage or deed of trust, then Tenant agrees, within ten (10) days
after Landlord’s written request therefor, to execute, acknowledge and deliver to Landlord any and all documents or instruments requested by Landlord or by such lessor or lender to assure the subordination of this Lease to such future ground
lease, mortgage or deed of trust, but only if such lessor or lender agrees not to disturb Tenant’s quiet possession of the Leased Premises so long as Tenant is not in default under this Lease beyond any applicable notice and cure periods
expressly set forth in this Lease, and subject to Tenant’s right to make reasonable comments to such documents or instruments (provided that Tenant shall not be entitled to object to any provision of such documents or instruments which is
substantially the same as a provision set forth in Exhibit I). Tenant’s failure to execute and deliver such documents or instruments within ten (10) days after Landlord’s request therefor shall be a material default by Tenant under
this Lease, provided that Landlord provides Tenant with a written notice of such default and Tenant continues to fail to deliver such documentation within four (4) days of receipt of such default notice, in which case no further notice shall be
required under Paragraph 12.1(c) or any other provision of this Lease, and Landlord shall have all of the rights and remedies available to Landlord as Landlord would otherwise have in the case of any other material default by Tenant, it being agreed
and understood by Tenant that Tenant’s failure to so deliver such documents or instruments in a timely manner could result in Landlord being unable to perform committed obligations to other third parties which were made by Landlord in reliance
upon this covenant of Tenant. If Landlord assigns the Lease as security for a loan, Tenant agrees to execute such documents as are reasonably requested by the lender and to provide reasonable provisions in the Lease protecting such lender’s
security interest which are customarily required by institutional lenders making loans secured by a deed of trust. 
 Tenant hereby agrees,
promptly upon request by Landlord, to execute, have acknowledged, and deliver to Landlord an SNDA substantially in the form of Exhibit I attached hereto, and Landlord agrees to cause Landlord’s existing mortgage lender to execute, have
acknowledged, and, as a condition to the effectiveness of this Lease, either (a) have the same recorded in the Official Records of Santa Clara County, or (b) deliver a complete original of the same to Tenant, in either case within 30 days
after the Effective Date of this Lease, failing which Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the end of such 30 day period, if at all. 

13.4 Tenant’s Attornment Upon Foreclosure. Tenant shall, upon request, attorn (i) to any purchaser of the Building, the
Property, or the Project at any foreclosure sale or private sale conducted pursuant to any security instruments encumbering the Building, the Property, or the Project, (ii) to any grantee or transferee designated in any deed given in lieu of
foreclosure of any security interest encumbering the Building, the Property, or the Project, or (iii) to the lessor under an underlying ground lease of the land underlying the Building, the Property, or the Project, should such ground lease be
terminated; provided that such purchaser, grantee or lessor recognizes Tenant’s rights under this Lease. 
 13.5 Mortgagee
Protection. In the event of any default on the part of Landlord, Tenant will give notice by registered mail to any Lender or lessor under any underlying ground lease who shall have requested, in writing, to Tenant that it be provided with such
notice, and Tenant shall offer such Lender or lessor a reasonable opportunity to cure the default. 
 13.6 Estoppel Certificate.
Tenant will, following any request by Landlord, promptly execute and deliver to Landlord an estoppel certificate substantially in form attached as Exhibit J, (i) certifying that this Lease is unmodified and in full force and effect, or,
if modified, stating the nature of such modification and certifying that this Lease, as so modified, is in full force and effect, (ii) stating the date to which the rent and other charges are paid in advance, if any, (iii) acknowledging
that there are not, to Tenant’s knowledge, any uncured defaults on the part of Landlord hereunder, or specifying such defaults if any are claimed, and (iv) certifying such other information about this Lease as may be reasonably requested
by Landlord, its Lender or prospective lenders, investors or purchasers of the Building, the Property, or the Project. Tenant’s failure to execute and deliver such estoppel certificate within ten (10) days after Landlord’s request
therefor shall be a material default by Tenant under this Lease, provided that Landlord provides Tenant with a written notice of such default and Tenant continues to fail to deliver such documentation within four (4) days of receipt of such
default notice, in which case no further notice shall be required under Paragraph 12.1(c) or any other provision of this Lease, and Landlord shall have all of the rights and remedies available to Landlord as Landlord would otherwise have in the case
of any other material default by Tenant, it being agreed and understood by Tenant that Tenant’s failure to so deliver such estoppel certificate in a timely manner could result in Landlord being unable to perform committed obligations to other
third parties which were made by Landlord in reliance upon this covenant of Tenant. Landlord and Tenant intend that any statement delivered pursuant to this paragraph may be relied upon by any Lender or purchaser or prospective Lender or purchaser
of the Building, the Property, or any interest in them. Tenant’s certifications are, however, made solely to estop Tenant from asserting against the party(ies) named therein (other than Landlord), facts or claims contrary

  
 37 

 Building D 
  

to those stated therein, and such estoppel certificate shall be binding on Tenant vis-à-vis the party(ies) named therein (other than Landlord) but shall not modify in any way,
Tenant’s relationship, obligations or rights vis-à-vis Landlord. 
 13.7 Tenant’s Financial Information. Tenant
shall, within ten (10) days after Landlord’s request therefor, deliver to Landlord a copy of Tenant’s (and any guarantor’s) current audited financial statements (including a balance sheet, income statement and statement of cash
flow, all prepared in accordance with generally accepted accounting principles), a list of all of Tenant’s creditors with current contact information, and any such other information reasonably requested by Landlord regarding Tenant’s
financial condition; provided, however, that as long as the common stock of Tenant (or its assigns permitted pursuant to this Lease or otherwise approved by Landlord in writing) is publicly-traded on a United States national stock exchange, and such
information is available as part of Tenant’s or such Permitted Transferee’s 10-K or 10-Q report filings on the SEC’s Edgar website, and such materials are current per SEC filing requirements, then such requirement shall be fulfilled
by such filings. Landlord shall be entitled to disclose such financial statements or other information to its Lender, to any present or prospective principal of or investor in Landlord, or to any prospective Lender or purchaser of the Building, the
Property, or any portion thereof or interest therein. Any such financial statement or other information which is marked “confidential” or “company secrets” (or is otherwise similarly marked by Tenant) shall be confidential and
shall not be disclosed by Landlord to any third party except as specifically provided in this paragraph, unless the same becomes a part of the public domain without the fault of Landlord. 

13.8 Transfer By Landlord. Landlord and its successors in interest shall have the right to transfer their interest in the Building, the
Property, or any portion thereof at any time and to any person or entity; provided, however, that if Landlord sells the Building at any time before the Warm Shell Components are Substantially Complete, Menlo Equities Development Company IX LLC
(“MEDCO IX”) will enter into a development agreement with the buyer pursuant to which MEDCO IX shall be the developer until the Warm Shell Components are Substantially Complete. In the event of any such transfer, the Landlord
originally named herein (and in the case of any subsequent transfer, the transferor), from the date of such transfer, shall be automatically relieved, without any further act by any person or entity, of all liability for (i) the performance of
the obligations of the Landlord hereunder which may accrue after the date of such transfer if its transferee agrees to assume and perform such obligations of the Landlord hereunder, and (ii) repayment of any unapplied portion of any security
deposit (upon transferring or crediting the same to the transferee). Tenant shall attorn to any such transferee. After the date of any such transfer, the term “Landlord” as used herein shall mean the transferee of such interest in the
Building, the Property, or the Project. 
 13.9 Force Majeure. Any prevention, delay or stoppage due to strikes, lockouts, labor
disputes, acts of God, acts of war, terrorist acts, inability to obtain services, labor, or materials or reasonable substitutes therefor, governmental actions, civil commotions, fire or other casualty, delay in obtaining approvals, building permits
and certificates of occupancy within normal time frames, and other causes beyond the reasonable control of the party obligated to perform, except with respect to the obligations imposed with regard to Rent and other charges to be paid by Tenant
pursuant to this Lease (collectively, a “Force Majeure”), notwithstanding anything to the contrary contained in this Lease, shall excuse the performance of such party for a period equal to any such prevention, delay or stoppage and,
therefore, if this Lease specifies a time period for performance of an obligation of either party, that time period shall be extended by the period of any delay in such party’s performance caused by a Force Majeure. 

13.10 Notices. Any notice required or permitted to be given under this Lease other than statutory notices, shall be in writing and
(i) personally delivered, (ii) sent by United States mail, registered or certified mail, postage prepaid, return receipt requested, or (iii) sent by Federal Express or similar nationally recognized overnight courier service, and in
all cases addressed as follows, and such notice shall be deemed to have been given upon the date of actual receipt or delivery (or refusal to accept delivery) at the address specified below (or such other addresses as may be specified by notice in
the foregoing manner) as indicated on the return receipt or air bill: 
  

			
	If to Landlord:		 Santa Clara Campus Property Owner I LLC

490 California Avenue
 4th Floor

Palo Alto, California 94306
 Attention: Henry Bullock/Richard
Holmstrom

		
	with a copy to:		 Mintz Levin Cohn Ferris Glovsky and Popeo PC
 44
Montgomery Street
 36th Floor

San Francisco, California 94104
 Attention: Paul
Churchill

  
 38 

 Building D 
  

			
		
	If to Tenant:		 Prior to the Lease Commencement Date:
 Aruba
Networks, Inc.
 1344 Crossman Avenue
 Sunnyvale, California
94089
 Attn: Mr. Michael Phelps,
 Sr. Director of Global
Real Estate

		
	With a copy to:		 Sheppard Mullin Richter & Hampton
 Four
Embarcadero Center
 17th Floor

San Francisco, California 94111
 Attention: Doug Van
Gessel

		
	If to Tenant:		 After the Lease Commencement Date:
 Aruba
Networks, Inc.
 3335 Scott Boulevard
 Santa Clara California
95054
 Attention: Mr. Michael Phelps,
 Sr. Director of
Global Real Estate

		
	with a copy to:		 Sheppard Mullin Richter & Hampton
 Four
Embarcadero Center
 17th Floor

San Francisco, California 94111
 Attention: Doug Van
Gessel

 Any notice given in accordance with the foregoing shall be deemed received upon actual receipt or refusal to accept delivery.
Any notice required by statute and not waived in this Lease shall be given and deemed received in accordance with the applicable statute or as otherwise provided by law. 

13.11 Attorneys’ Fees and Costs. In the event any party shall bring any action, arbitration, or other proceeding alleging a breach
of any provision of this Lease, or a right to recover rent, to terminate this Lease, or to enforce, protect, interpret, determine, or establish any provision of this Lease or the rights or duties hereunder of either party, the prevailing party shall
be entitled to recover from the non-prevailing party as a part of such action or proceeding, or in a separate action for that purpose brought within one year from the determination of such proceeding, reasonable attorneys’ fees, expert witness
fees, court costs and reasonable disbursements, made or incurred by the prevailing party. 
 13.12 Definitions. Any term that is
given a special meaning by any provision in this Lease shall, unless otherwise specifically stated, have such meaning wherever used in this Lease or in any Addenda or amendment hereto. In addition to the terms defined in Article 1, the following
terms shall have the following meanings: 
 (a) Real Property Taxes. The term “Real Property Tax” or “Real
Property Taxes” shall each mean Tenant’s Building Share of the following (to the extent applicable to any portion of the Lease Term, regardless of when the same are imposed, assessed, levied, or otherwise charged): (i) all taxes,
assessments, levies and other charges of any kind or nature whatsoever, general and special, foreseen and unforeseen (including all installments of principal and interest required to pay any general or special assessments for public improvements and
any increases resulting from reassessments caused by any change in ownership or new construction), now or hereafter imposed by any governmental or quasi-governmental authority or special district having the direct or indirect power to tax or levy
assessments, which are levied or assessed for whatever reason against the Property or any portion thereof, or Landlord’s interest herein, or the fixtures, equipment and other property of Landlord that is an integral part of the Property and
located thereon, or Landlord’s business of owning, leasing or managing the Property or the gross receipts, income or rentals from the Property, (ii) all charges, levies or fees imposed by any governmental authority against Landlord by
reason of or based upon the use of or number of parking spaces within the Property, the amount of public services or public utilities used or consumed (e.g. water, gas, electricity, sewage or waste water disposal) at the Property, the number of
persons employed by tenants of the Property, the size (whether measured in area, volume, number of tenants or whatever) or the value of the Property, or the type of use or uses conducted within the Property, and all costs and fees (including
attorneys’ fees) reasonably incurred by Landlord in contesting in good faith any Real Property Tax and in negotiating with public authorities as to any Real Property Tax. In the event the Project is developed in a manner which results in
separate legal parcels comprising some or all of the Common Areas, then with respect to those Common Area parcels, Real Property Taxes shall be calculated using Tenant’s Project Share (as opposed to Tenant’s Building Share). If, at any
time during the Lease Term, the taxation or assessment of the Property prevailing as of the Effective Date of this Lease shall be altered so that in lieu of or in addition to any the Real Property Tax described above there

  
 39 

 Building D 
  

shall be levied, awarded or imposed (whether by reason of a change in the method of taxation or assessment, creation of a new tax or charge, or any other cause) an alternate, substitute, or
additional use or charge (i) on the value, size, use or occupancy of the Property or Landlord’s interest therein or (ii) on or measured by the gross receipts, income or rentals from the Property, or on Landlord’s business of
owning, leasing or managing the Property or (iii) computed in any manner with respect to the operation of the Property, then any such tax or charge, however designated, shall be included within the meaning of the terms “Real Property
Tax” or “Real Property Taxes” for purposes of this Lease. Notwithstanding the foregoing, the terms “Real Property Tax” or “Real Property Taxes” shall not include estate, inheritance, gift or franchise taxes of
Landlord or the federal or state income tax imposed on Landlord’s income from all sources, transfer taxes, any items which are in the nature of Taxes but are included in Property Maintenance Costs (in which case they shall be payable under that
category) or expressly are excluded from Property Maintenance Costs (in which case they shall not be payable by Tenant), including, without limitation, certain of the items excluded pursuant to Paragraph 13.12(xviii) below) and any real estate taxes
directly payable by Tenant or any other tenant of the Project (i.e., not paid by Landlord) under the applicable provisions of their respective leases. If Landlord receives a refund of Real Property Taxes or a credit against its future Real Property
Taxes for any calendar year during the Lease Term for which Tenant paid Tenant’s Share of Real Property Taxes, Landlord shall, at its election, either pay to Tenant, or credit against subsequent payments of Rent due hereunder, an amount equal
to Tenant’s Building Share or Tenant’s Project Share (as applicable) of the refund, net of any reasonable, actual out-of-pocket expenses incurred by Landlord in achieving such refund; provided, however, if this Lease shall have expired or
is otherwise terminated, Landlord shall refund in cash any such refund or credit due to Tenant within thirty (30) days after Landlord’s receipt of such refund or its receipt of such credit against future Real Property Taxes.
Landlord’s obligation to so refund to Tenant any such refund or credit of Real Property Taxes shall survive such expiration or termination. If the Fitness Center is used only by certain tenants of the Project or Property, then Landlord shall
have the right to allocate Real Property Taxes attributable to such Fitness Center solely to those tenants who have access to the Fitness Center. 

(b) Landlord’s Insurance Costs. The term “Landlord’s Insurance Costs” shall mean (to the extent applicable
to any portion of the Lease Term, regardless of when the same are incurred): 
 (i) Tenant’s Building Share of the costs to Landlord
to carry and maintain the policies of fire and property damage insurance for the Building and general liability and any other insurance required or permitted to be carried by Landlord pursuant to Article 9, together with any deductible amounts paid
by Landlord upon the occurrence of any insured casualty or loss, but only to the extent such deductible is not in excess of Fifty Thousand Dollars ($50,000) per occurrence for non-earthquake insurance policies and not in excess of five percent
(5%) per occurrence of the full replacement cost of the Building in the case of policies of earthquake insurance; provided that if Tenant’s Project Share or Tenant’s Building Share, as relevant, of any earthquake deductible will
exceed an amount equal to Two and 00/100 Dollars ($2.00) per square foot of the rentable area in the Leased Premises in a particular calendar year (the “Annual Casualty Deductible Cap”) then only an amount up to such Annual Casualty
Deductible Cap shall be paid by Tenant in any calendar year, but Tenant’s Project Share or Tenant’s Building Share, as relevant, of excess amounts of such deductible may be carried forward, subject to the same Annual Casualty Deductible
Cap limitation, for payment in each subsequent year, up to the expiration or earlier termination of the Lease Term (as the same may be extended). If Tenant terminates this Lease under Article 10 as a result of a casualty, Tenant’s obligation to
pay any deductible with respect to that casualty shall not exceed Fifty Thousand Dollars ($50,000) (if the casualty is not the result of an earthquake) or the Annual Casualty Deductible Cap (if the casualty is the result of an earthquake). If
Landlord terminates this Lease under Article 10 as a result of a casualty, Tenant shall have no obligation to pay Landlord’s insurance deductible; plus 

(ii) without duplication of amounts payable pursuant to subparagraph (i) above, to the extent any of the insurance policies carried by
Landlord are specific to the Project as a whole (as opposed to the Building or the Property), then, Tenant’s Project Share of the costs to Landlord to carry and maintain the policies of fire and property damage insurance for the Project (as
opposed to just the Building or the Property) and general liability and any other insurance required or permitted to be carried by Landlord pursuant to Article 9 which is applicable to the Project (as opposed to just the Building or the Property),
together with any deductible amounts paid by Landlord upon the occurrence of any insured casualty or loss to the extent permitted pursuant to Paragraph 13.12(b)(i) above. 

(c) Property Maintenance Costs. The term “Property Maintenance Costs” shall mean (to the extent applicable to any
portion of the Lease Term, regardless of when the same are incurred): 
 (i) monthly professional management fees equal to 2.5% of Base
Monthly Rent (the “Management Fee”), plus Tenant’s Building Share of all other costs and expenses (except Landlord’s Insurance Costs and Real Property Taxes) paid or incurred by Landlord in protecting, operating,
maintaining, repairing and preserving the Building and the Property and all parts thereof, 

  
 40 

 Building D 
  

including without limitation, (A) the amortizing portion of any costs incurred by Landlord in the making of any modifications, alterations or improvements required by any governmental
authority as set forth in Article 6, which are so amortized during the Lease Term, and (B) such other costs as may be paid or incurred with respect to operating, maintaining, and preserving the Building or the Property, such as repairing and
resurfacing the exterior surfaces of the Building (including roofs), repairing and replacing structural parts of the Building, and repairing and replacing, when necessary, electrical, plumbing, and HVAC systems serving the Building; provided,
however, that Tenant shall not be responsible for any capital repairs or replacements costing over $10,000 individually, which are incurred by Landlord during the initial, unextended Lease Term except to the extent such capital repairs or
replacements are necessitated by Tenant’s breach of this Lease, and subject to the last two (2) sentences of Paragraph 5.1(b) above; plus 

(ii) without limitation or duplication of the foregoing, Tenant’s Project Share of all costs and expenses (except Landlord’s
Insurance Costs and Real Property Taxes) paid or incurred by Landlord in protecting, operating, maintaining, repairing and preserving the Project (as opposed to just the Building or the Property) and all parts thereof (excluding the Building and the
Other Buildings); plus 
 (iii) costs of maintaining, repairing, and operating the Fitness Center and, notwithstanding any contrary
allocation pursuant to Tenant’s Project Share, shall be allocated among the Building, Buildings A, B, and C, and any additional buildings in the Project that have the use of the Fitness Center, and any buildings that do not have the use of such
Fitness Center shall be excluded from such allocation; plus 
 (iv) without limitation or duplication of the foregoing, Tenant’s
Project Share of all costs and expenses paid or incurred by Landlord for employee shuttles and other transportation management efforts at the Project. 

(d) Property Operating Expenses. The term “Property Operating Expenses” shall mean and include all Real Property
Taxes, plus all Landlord’s Insurance Costs, plus all Property Maintenance Costs. If the occupancy of the Building or Project, during any calendar year is less than ninety-five percent (95%), Landlord shall make adjustments to the variable
components of Property Operating Expenses for that calendar year, as reasonably determined by Landlord to determine the amount of Property Operating Expenses that would have been incurred had the Building and Project been ninety-five percent
(95%) occupied. Such adjusted variable components of Property Operating Expenses will be considered to have been the amount of Property Operating Expenses for that calendar year for reimbursement purposes hereunder. For purposes hereunder, the
term “variable components” includes only those components of Property Operating Expenses that are affected by variations in occupancy levels as determined by Landlord. 

Notwithstanding the provisions of Paragraph 13.12(c), the following are specifically excluded from the definition of Property Operating Expenses and Tenant
shall have no obligation to pay directly or reimburse Landlord for all or any portion of the following except to the extent any of the following are caused by the actions or inactions of Tenant, or result from the failure of Tenant to comply with
the terms of this Lease: 
 (i) Landlord’s non-cash charges, such as depreciation (except for the amortization of capital or other
items to the extent provided for in this Lease), 
 (ii) any payments of points, interest or principal relating to any debt secured by the
Leased Premises, 
 (iii) costs associated with the operation of the business of the ownership or entity which constitutes
“Landlord” (as distinguished from the costs of Leased Premises operations), including, but not limited to, partnership accounting and legal matters, accounting, payroll, legal and computer services, costs of defending any lawsuits with any
mortgagee, costs of selling, syndicating, financing, mortgaging or hypothecating any of Landlord’s interest in the Leased Premises, costs of any disputes between Landlord and its employees (if any) whether or not engaged in Leased Premises
operation, or outside fees paid in connection with disputes with other tenants, 
 (iv) legal fees, space planners’ fees, real estate
brokers’ leasing commissions, and advertising expenses incurred in connection with leasing of the Leased Premises, 
 (v) costs for
which Landlord is reimbursed by its insurance carrier or any tenant’s insurance carrier, 
 (vi) any bad debt loss, rent loss or
reserves for bad debts or rent loss, 

  
 41 

 Building D 
  

(vii) any interest or late fee resulting from any failure of Landlord to pay any item of Property Operating Expenses when it would have been
due without such interest or late fee; provided, however, that nothing herein shall be deemed from precluding Landlord from passing through to Tenant as a Property Operating Expense any cost associated with paying Property Operating Expenses on any
permitted installment or other periodic basis, even if such payment basis results in an increase in the Property Operating Expense in question, 

(viii) overhead and profit increment paid to Landlord or to subsidiaries or affiliates of Landlord for such services in the Leased Premises
to the extent the same exceeds the costs of such services rendered by unaffiliated third parties on a competitive basis (but the foregoing shall not limit Tenant’s obligation to pay the Management Fee described in Paragraph 13.12(b) above),

 (ix) costs of repairs or rebuilding necessitated by condemnation except as otherwise provided in this Lease, or the portion(s) of any
insurance deductibles that are excluded in Section 13.12(b)(i) above 
 (x) space planning fees and commissions, 

(xi) expenses for repairs, replacements or improvements to the extent such expenses are reimbursed by warranties from contractors,
manufacturers or suppliers, or are otherwise borne by parties other than Landlord, 
 (xii) repairs, alterations, additions, improvements
or replacements made pursuant to Paragraph 2.8, 
 (xiii) costs incurred due to Landlord’s violation of any terms and conditions of
this Lease, any other lease or occupancy agreement at the Project, any contract or agreement relating to the Project or any part thereof (including Restrictions), or of any law, ordinance or governmental rule or regulation affecting the Building,

 (xiv) costs of repairs or other work occasioned by casualty (to the extent the cost of the repairs is reimbursed by insurance), 

(xv) costs incurred to remove, remedy, contain or treat any Hazardous Materials, except to the extent that such costs arise in the ordinary
course of maintenance of an office building campus in the general locale of the Project or result from the acts or omissions of Tenant or any of Tenant’s Parties; provided, however, that nothing herein shall be deemed to modify or lessen the
obligations of Tenant pursuant to Section 4.11 of this Lease, 
 (xvi) reserves of any kind, 

(xvii) costs of rentals for items which if purchased, rather than rented, would constitute a capital improvement or equipment other than
Permitted Capital Expenditures; 
 (xviii) the following costs, expenses and fees to the extent incurred in connection with the initial
construction, entitlement and development of the Project: (A) all fees and costs attributable to compliance with Landlord’s conditions of approval for the Project (e.g., mitigation fees, impact fees, subsidies, tap-in fees, development
fees, connection fees or similar one-time charges or costs (however characterized), (B) lump sum assessments or payments under any public or private infrastructure payment districts, (C) costs of traffic studies, transportation management
reports, and establishment of transportation management plans, and (D) environmental impact reports, except that Property Maintenance Costs shall include (or such costs may be charged directly to Tenant, if applicable) any on-going operational
costs incurred by Landlord that are set forth in Landlord’s entitlements, permits or other approvals for the development of the Project, including but not limited to transportation management plans and/or the conditions of approval and
development agreement therefor, or any such ongoing operational costs of any future programs or requirements which are either referenced in such entitlements, permits or approvals or which are a logical evolution thereof and are subsequently
required by the governmental agencies implementing such entitlements, permits or approvals, 
 (xix) any payments under a ground lease
relating to the Project, Building or Leased Premises, 
 (xx) costs, including permit, license and inspection costs, incurred with respect
to the installation of other tenants’ or other occupants’ improvements made for other tenants or other occupants at the Project or incurred in renovating or otherwise improving, decorating, painting or redecorating space (excluding Common
Areas) for tenants or other occupants of the Project, 

  
 42 

 Building D 
  

(xxi) any assessment and premiums for time periods other than the Lease Term (but overlapping assessment or premium periods may be prorated
and the amounts allocable to the lease term shall be included in Property Operating Costs), 
 (xxii) marketing and promotional costs,
including but not limited to leasing commissions, real estate brokerage commissions, and attorneys’ fees in connection with the negotiation and preparation of letters, deal memos, letters of intent, leases, subleases and/or assignments, space
planning costs, and other costs and expenses incurred in connection with lease, sublease and/or assignment negotiations and transactions with present or prospective tenants or other occupants of the Project, including Tenant (but no costs arising
from Article 7 shall be excluded by this subparagraph), 
 (xxiii) costs of services, utilities, or other benefits which are not offered to
Tenant or for which Tenant is charged for directly but which are provided to another tenant or occupant of the Project, including, but not limited to, above Building standard heating, ventilation and air-conditioning, and janitorial services, 

(xxiv) all items and services for which Tenant or any other tenant at the Project reimburses Landlord or pays directly (as opposed to paying
the same through Tenant’s Building Share or Tenant’s Project Share or any other tenant’s share of Property Operating Costs), including electric power or other utility costs for which any tenant directly contracts with the local public
service company, 
 (xxv) advertising and promotional expenditures, including but not limited to tenant newsletters and Project or Building
promotional gifts, events or parties for existing or potential future occupants, and the costs of signs (other than the Building directory) in or on the Project identifying the owner of the Building or other tenants’ signs; 

(xxvi) any cost or expense arising solely in connection with the initial entitlement, development, and construction of the Other Buildings;

 (xxvii) any cost which is expressly excluded from Property Operating Expenses, Real Property Taxes, or Property Maintenance Costs
pursuant to a different provision of this Lease. 
 (xxviii) costs, other than those incurred in ordinary maintenance and repair, for
sculpture, paintings, fountains or other objects of art, 
 (xxix) costs (including in connection therewith all attorneys’ fees and
costs of settlement judgments and payments in lieu thereof) arising from claims, disputes or potential disputes in connection with potential or actual claims, litigation or arbitrations pertaining to Landlord and/or the Building, the Other Buildings
and/or the Project; 
 (xxx) the cost of any work or services performed for any tenant (including Tenant) at such tenant’s cost for
which Landlord has been reimbursed, 
 (xxxi) payments to Landlord or to subsidiaries or affiliates of Landlord for services in the
Building to the extent the same exceeds the fair market costs of such services rendered by unaffiliated comparable third parties, 

(xxxii) the cost of any parties, ceremonies or other events for tenants, Landlord, Landlord’s affiliates or third parties, whether
conducted in the Building, the Project or in any other location; 
 (xxxiii) costs incurred by Landlord in connection with rooftop
communications equipment of Landlord or other persons, tenants or occupants on the Building or the Project; 
 (xxxiv) “takeover”
expenses, including, but not limited to, the expenses incurred by Landlord with respect to space located in another building of any kind or nature in connection with the leasing of space in the Building, 

(xxxv) any costs, fees, dues, contributions or similar expenses for industry associations or similar organizations, and Landlord’s
charitable or political contributions, 
 (xxxvi) any costs associated with the purchase or rental or furniture, fixtures or equipment for
any management, security, engineering, or other offices associated with the Project and Common Areas (other than the Fitness Center) or for Landlord’s offices or the offices of other landlords of the Project or for the Common Areas of the
Building or Project, 
 (xxxvii) wages, fees, operating expenses and taxes incurred in connection with the ownership, management and
operation of commercial concessions operated by Landlord, 

  
 43 

 Building D 
  

(xxxviii) the entertainment expenses and travel expenses of Landlord, its employees, agents, partners and affiliates, 

(xxxix) any costs for which Landlord has been reimbursed or receives a credit or refund or to the extent of any discount, provided if
Landlord receives the same in connection with any costs or expenditures previously included in Property Operating Expenses for an expense year, Landlord shall promptly reimburse Tenant for any overpayment for such previous expense year; and 

(xl) all items and services for which Tenant or any other tenant at the Project reimburses Landlord or pays directly (as opposed to paying
the same through Tenant’s Building Share or Tenant’s Project Share or any other tenant’s share of Property Operating Costs), including electric power or other utility costs for which any tenant directly contracts with the local public
service company, and 
 (xli) the costs of obtaining any initial LEED certification of the Building; provided, however, that nothing herein
shall be deemed to prevent Landlord from including in Property Operating Costs any subsequent costs of complying with the operational requirements of that LEED certification. 

It is understood that Property Maintenance Expenses shall be calculated net of all cash discounts, trade discounts, or quantity discounts received by Landlord
or Landlord’s managing agent in the purchase of any goods, utilities, or services which are the basis of the specific Property Maintenance Expense. In the calculation of any expenses hereunder, it is understood that Landlord will not charge
Tenant more than one hundred percent (100%) of any Property Maintenance Expenses due hereunder. Landlord and Tenant also agree that it is their intention that no Property Maintenance Expenses (or exclusions therefrom be duplicated. 

(e) Law. The term “Law” or “Laws” shall mean any judicial decisions and any statute, constitution,
ordinance, resolution, regulation, rule, code, administrative order, condition of approval, or other requirements of any municipal, county, state, federal, or other governmental agency or authority having jurisdiction over the parties to this Lease,
the Leased Premises, the Building, the Property, or the Project, or any of them, in effect either at the Effective Date of this Lease or at any time during the Lease Term, including, without limitation, any regulation, order, or policy of any
quasi-official entity or body (e.g. a board of fire examiners or a public utility or special district). Except to the extent otherwise expressly provided in this Lease, to the extent any Law or Restriction places limits on the Building or any
portion thereof, or on the Property or the Project or any portion thereof, such limits shall be equitably allocated to the Leased Premises pro rata in the same proportion that the rentable square footage of the Leased Premises bears to the rentable
square footage of the applicable Building or portion thereof, or the Property or the Project or portion thereof, as applicable. 
 (f)
Lender. The term “Lender” shall mean the holder of any promissory note or other evidence of indebtedness secured by the Property or any portion thereof. 

(g) Rent. The term “Rent” shall mean collectively Base Monthly Rent and all Additional Rent. 

(h) Restrictions. The term “Restrictions” shall mean (as they may exist from time to time) any and all covenants,
conditions and restrictions, private agreements, easements, and any other recorded documents or instruments affecting the use of the Property, the Building, the Leased Premises, or the Common Areas; provided, however, that the Required Conditions
(as defined in Paragraph 2.2(a) of this Lease) must be satisfied with respect to any future Restrictions imposed by Landlord (as opposed to those which may be imposed by a governmental or quasi-governmental agency). 

13.13 General Waivers. One party’s consent to or approval of any act by the other party requiring the first party’s consent
or approval shall not be deemed to waive or render unnecessary the first party’s consent to or approval of any subsequent similar act by the other party. No waiver of any provision hereof, or any waiver of any breach of any provision hereof,
shall be effective unless in writing and signed by the waiving party. The receipt by Landlord of any rent or payment with or without knowledge of the breach of any other provision hereof shall not be deemed a waiver of any such breach. No waiver of
any provision of this Lease shall be deemed a continuing waiver unless such waiver specifically states so in writing and is signed by both Landlord and Tenant. No delay or omission in the exercise of any right or remedy accruing to either party upon
any breach by the other party under this Lease shall impair such right or remedy or be construed as a waiver of any such breach theretofore or thereafter occurring. The waiver by either party of any breach of any provision of this Lease shall not be
deemed to be a waiver of any subsequent breach of the same or any other provisions herein contained. 
 13.14 Miscellaneous. Should
any provisions of this Lease prove to be invalid or illegal, such invalidity or illegality shall in no way affect, impair or invalidate any other provisions hereof, and such remaining provisions shall remain in full force and effect. Time is of the
essence with respect to the 

  
 44 

 Building D 
  

performance of every provision of this Lease in which time of performance is a factor. Any copy of this Lease which is executed by the parties shall be deemed an original for all purposes. This
Lease shall, subject to the provisions regarding assignment, apply to and bind the respective heirs, successors, executors, administrators and assigns of Landlord and Tenant. The term “party” shall mean Landlord or Tenant as the
context implies. If Tenant consists of more than one person or entity, then all members of Tenant shall be jointly and severally liable hereunder. If this Lease is signed by an individual “doing business as” or
“dba” another person or entity or entity name, the individual who signs this Lease will be deemed to be the Tenant hereunder for all purposes. Submission of this Lease for review, examination or signature by Tenant does not
constitute an offer to lease, a reservation of or an option for lease, or a binding agreement of any kind, and notwithstanding any inconsistent language contained in any other document, this Lease is not effective as a lease or otherwise until
execution and delivery by both Landlord and Tenant, and prior to such mutual execution and delivery, neither party shall have any obligation to negotiate and may discontinue discussions and negotiations at any time for any reason or no reason. This
Lease shall be construed and enforced in accordance with the Laws of the State in which the Leased Premises are located. The headings and captions in this Lease are for convenience only and shall not be construed in the construction or
interpretation of any provision hereof. When the context of this Lease requires, the neuter gender includes the masculine, the feminine, a partnership, corporation, limited liability company, joint venture, or other form of business entity, and the
singular includes the plural. The terms “must,” “shall,” “will,” and “agree” are mandatory. The term “may” is permissive. The term “governmental agency” or “governmental
authority” or similar terms shall include, without limitation, all federal, state, city, local and other governmental and quasi-governmental agencies, authorities, bodies, boards, etc., and any party or parties (other than Landlord or a
Landlord affiliate) having enforcement rights under any Restrictions. When a party is required to do something by this Lease, it shall do so at its sole cost and expense without right of reimbursement from the other party unless specific provision
is made therefor. Where Landlord’s consent is required hereunder, it shall be reasonable for any such consent to be withheld until Landlord’s receipt of the consent of any Lender, if and to the extent Landlord is required to obtain such
Lender’s consent. Landlord and Tenant shall both be deemed to have drafted this Lease, and the rule of construction that a document is to be construed against the drafting party shall not be employed in the construction or interpretation of
this Lease. Where Tenant is obligated not to perform any act or is not permitted to perform any act, Tenant is also obligated to restrain any others reasonably within its control, including agents, invitees, contractors, subcontractors and
employees, from performing such act. Landlord shall not become or be deemed a partner or a joint venturer with Tenant by reason of any of the provisions of this Lease. 

13.15 Further Development and Subdivision. Notwithstanding anything to the contrary contained herein, Landlord itself and through its
agents, employees and contractors shall be entitled to sell one or more parcels or buildings located on the Project, and to further improve the Project, including by constructing additional buildings and a parking structure, in the event that
Landlord or its affiliate has or obtains the legal right to further develop the Project, either alone or in connection with acquiring property adjacent to the Project. Such sale and development efforts by Landlord may include, without limitation,
the relocation, restriping, or reconfiguration of the parking areas so long as the Required Conditions are satisfied, application for building permits use permits, and other development approvals, parcelization, lot combination or merger, or lot
line adjustment of the Property or Project, and construction of buildings and parking structures. Tenant agrees to execute such reasonable documents and take such actions as reasonably necessary to assist Landlord with such efforts and actions,
provided such documents do not materially increase Tenant’s obligations or materially diminish Tenant’s rights under the Lease. Tenant agrees that such efforts and actions of Landlord shall not constitute constructive eviction of Tenant
from the Project, the Property, or the Leased Premises. Following any parcelization, lot combination or merger, or lot line adjustment of the Property or the Project, Landlord and Tenant agree to amend this Lease to conform the descriptions of the
Property, Project, Site Plan, and Common Areas, and (subject to there being no decrease in the number of parking spaces to which Tenant is entitled) the parking areas contained herein, to the parcelization, lot combination or merger, lot line
adjustment, or reconfiguration. Landlord agrees to minimize the disruption of Tenant’s use of the Leased Premises, the Building, the Common Areas and the Project to the extent reasonable, given Landlord’s efforts and actions described
herein. In connection with any sale or subdivision of a portion of the Project, Landlord may amend the description of the Common Areas, so long as the Required Conditions are satisfied. 

13.16 Patriot Act Compliance. 

(a) Tenant will use its good faith and commercially reasonable efforts to comply with the Patriot Act (as defined below) and all applicable
requirements of governmental authorities having jurisdiction over Tenant, the Property, or the Project, including those relating to money laundering and terrorism. Landlord shall have the right to audit Tenant’s compliance with the Patriot Act
and all applicable requirements of governmental authorities having jurisdiction over Tenant, the Property, or the Project, including those relating to money laundering and terrorism. In the event that Tenant fails to comply with the Patriot Act or
any such requirements of governmental authorities, then Landlord may, at its option, cause Tenant to comply therewith and any and all reasonable costs and expenses incurred by 

  
 45 

 Building D 
  

Landlord in connection therewith shall be deemed Additional Charges and Rent and shall be immediately due and payable. For purposes hereof, the term “Patriot Act” means the
Uniting and Strengthening America by Providing Appropriate Tools Required to Intercept and Obstruct Terrorism (USA PATRIOT ACT) Act of 2001, as the same may be amended from time to time, and corresponding provisions of future laws. 

(b) Neither Tenant nor any partner in Tenant or member of such partner nor any owner of a direct or indirect interest in Tenant (a) is
listed on any Government Lists (as defined below), (b) is a person who has been determined by competent authority to be subject to the prohibitions contained in Presidential Executive Order No. 13224 (Sept. 23, 2001) or any other similar
prohibitions contained in the rules and regulations of OFAC (as defined below) or in any enabling legislation or other Presidential Executive Orders in respect thereof, (c) has been previously indicted for or convicted of any felony involving a
crime or crimes of moral turpitude or for any Patriot Act Offense (as defined below), or (d) is currently under investigation by any governmental authority for alleged criminal activity. For purposes hereof, the term “Patriot Act
Offense” means any violation of the criminal laws of the United States of America or of any of the several states, or that would be a criminal violation if committed within the jurisdiction of the United States of America or any of the
several states, relating to terrorism or the laundering of monetary instruments, including any offense under (a) the criminal laws against terrorism; (b) the criminal laws against money laundering, (c) the Bank Secrecy Act, as
amended, (d) the Money Laundering Control Act of 1986, as amended, or the (e) Patriot Act. “Patriot Act Offense” also includes the crimes of conspiracy to commit, or aiding and abetting another to commit, a Patriot
Act Offense. For purposes hereof, the term “Government Lists” means (i) the Specially Designated Nationals and Blocked Persons Lists maintained by Office of Foreign Assets Control (“OFAC”), (ii) any other
list of terrorists, terrorist organizations or narcotics traffickers maintained pursuant to any of the Rules and Regulations of OFAC or pursuant to any Executive Order of the President of the United States of America. 

13.17 Restrictions on Leasing to Certain Competitors. Provided that and for so long as (a) Tenant is Aruba Networks, Inc. [NASDAQ:
ARUN] or a Permitted Transferee, (b) it is occupancy of at least five (5) full floors of the Building and one (1) full floor of Building C, and (c) it is not in a monetary or a material non-monetary default under this Lease with
respect to which Landlord is exercising remedies pursuant to the California Civil Code, then during the Lease Term (as the same may be extended pursuant to Article 15 below), Landlord shall not, without Tenant’s approval, lease space
(i) in the Building or Building A, Building B, or Building C to Cisco Systems, Inc., Aerohive Networks, Inc., or Ruckus Wireless, Inc., and (ii) in the Building or Building C to Huawei Technologies Co. Ltd., Meraki, Inc., Ubiquiti
Networks, Inc., or Meru Networks, Inc. Notwithstanding the foregoing, it shall not constitute a breach of this Paragraph 13.17 if any tenants of the Project assign or sublease to any of the foregoing companies, nor if Landlord extends the lease of a
tenant so acquired or permits the expansion of space leased thereunder. In addition, this provision shall not apply to a tenant who is acquired by one of these companies whether or not it remains a separate company or is merged into the acquirer.

 ARTICLE 14 
 LEGAL
AUTHORITY 
 BROKERS AND ENTIRE AGREEMENT 

14.1 Legal Authority. Each of Landlord and Tenant hereby represents and warrants to the other that it is validly formed and duly
authorized and existing, that it is qualified to do business in the State in which the Leased Premises are located, that it has the full right and legal authority to enter into this Lease, and that such party’s signatory(ies) are duly
authorized to execute and deliver this Lease on behalf of such party. Tenant shall, within ten (10) days after the Effective Date of this Lease, deliver to Landlord a certified copy of the resolution of its board of directors authorizing or
ratifying the execution of this Lease. Landlord shall, within ten (10) days after the Effective Date of this Lease, deliver to Tenant an original or a certified copy of the resolution of its Members authorizing or ratifying the execution of
this Lease. 
 14.2 Brokerage Commissions. 

(a) Tenant represents, warrants and agrees that it has not had any dealings with any real estate broker(s), leasing agent(s), finder(s) or
salesmen, other than the Brokers (as named in Article 1) with respect to the lease by it of the Leased Premises pursuant to this Lease, and that it will indemnify, defend with competent counsel, and hold Landlord harmless from any liability for the
payment of any real estate brokerage commissions, leasing commissions or finder’s fees claimed by any other real estate broker(s), leasing agent(s), finder(s), or salesmen to be earned or due and payable by reason of Tenant’s agreement or
promise (implied or otherwise) to pay (or to have Landlord pay) such a commission or finder’s fee by reason of its leasing the Leased Premises pursuant to this Lease. 

(b) Landlord represents, warrants and agrees that it has not had any dealings with any real estate broker(s), leasing agent(s), finder(s) or
salesmen, other than the Brokers (as named in 

  
 46 

 Building D 
  

Article 1) with respect to the lease by it of the Leased Premises pursuant to this Lease, and that it will indemnify, defend with competent counsel, and hold Tenant harmless from any liability
for the payment of any real estate brokerage commissions, leasing commissions or finder’s fees claimed by any other real estate broker(s), leasing agent(s), finder(s), or salesmen to be earned or due and payable by reason of Landlord’s
agreement or promise (implied or otherwise) to pay (or to have Tenant pay) such a commission or finder’s fee by reason of its leasing the Leased Premises pursuant to this Lease. 

(c) Landlord shall pay the Brokers a commission pursuant to a separate agreement between Landlord and each Broker. 

(d) Notwithstanding any provision of this Lease to the contrary, Landlord is not obligated to pay any leasing commission or compensation of
any kind or type in connection with an extension of the term of this Lease, an expansion of the Leased Premises, a lease or sublease of any other premises leased by Tenant pursuant to any right of first offer or right of first refusal or other
similar right granted to Tenant, unless such obligation is set forth in the separate agreements between Landlord and each Broker described above. 

14.3 Entire Agreement. This Lease and the Exhibits (as described in Article 1), which Exhibits are by this reference incorporated
herein, constitute the entire agreement between the parties, and there are no other agreements, understandings or representations between the parties relating to the lease by Landlord of the Leased Premises to Tenant, except as expressed herein. No
subsequent changes, modifications or additions to this Lease shall be binding upon the parties unless in writing and signed by both Landlord and Tenant. 

14.4 Landlord’s Representations. Tenant acknowledges that neither Landlord nor any of its agents made any representations or
warranties respecting the Property, the Building or the Leased Premises, upon which Tenant relied in entering into the Lease, which are not expressly set forth in this Lease. Tenant further acknowledges that neither Landlord nor any of its agents
made any representations as to (i) whether the Leased Premises may be used for Tenant’s intended use under existing Law, or (ii) the suitability of the Leased Premises for the conduct of Tenant’s business, or (iii) the exact
square footage of the Leased Premises or the Building, and that Tenant relies solely upon its own investigations with respect to such matters. Tenant expressly waives any and all claims for damage by reason of any statement, representation,
warranty, promise or other agreement of Landlord or Landlord’s agent(s), if any, not contained in this Lease or in any Exhibit attached hereto. 

ARTICLE 15 
 OPTIONS TO
EXTEND 
 15.1 Options to Extend. So long as Aruba Networks, Inc. or a Permitted Assignee is the Tenant hereunder and occupies at
least three (3) contiguous full floors of the Leased Premises, and subject to the conditions set forth below, Tenant shall have two options to extend the term of this Lease with respect to three (3) or more contiguous full floors of the
Leased Premises (but not more space than then being leased by Tenant at the time the applicable extension option is exercised), the first for a period of five (5) years from the expiration of the initial, unextended Lease Term (the
“First Extension Period”), and the second (the “Second Extension Period”) for a period of five (5) years from the expiration of the First Extension Period, subject to the following conditions: 

(a) Each option to extend shall be exercised, if at all, by notice of exercise given to Landlord by Tenant not more than twelve
(12) months nor less than nine (9) months prior to the expiration of the initial, unextended Lease Term or the expiration of the First Extension Period, as applicable; 

(b) If Tenant exercises either extension option for less that the entire five (5) floors of the initial Leased Premises (or less than the
entire five (5) floors of the initial Leased Premises plus the Identified ROFR Space, if it is added to the Leased Premises pursuant to Paragraph 17.1 below), the floors with respect to which Tenant exercises such option(s) must include the
top-most floor, or bottom-most floor, then being leased at the time the applicable option is exercised. 
 (c) Anything herein to the
contrary notwithstanding, if Tenant is in monetary or material non-monetary default under any of the terms, covenants or conditions of this Lease, either at the time Tenant exercises either extension option or on the commencement date of the First
Extension Period or the Second Extension Period, as applicable, Landlord shall have, in addition to all of Landlord’s other rights and remedies provided in this Lease, the right to terminate such option(s) to extend upon notice to Tenant within
five (5) business days after receipt of Tenant’s extension notice or else Landlord shall be deemed to have waived Landlord’s right to terminate such option. For the avoidance of confusion, the foregoing shall not be read to prevent
Tenant from curing the applicable default and then exercising the applicable option to extend once the default is cured if such cure is completed within the applicable cure period, if any, expressly set forth in this Lease.

  
 47 

 Building D 
  

15.2 Fair Market Rent. In the event the applicable option is exercised in a timely fashion, the Lease shall be extended for the term of
the applicable extension period upon all of the terms and conditions of this Lease, provided that the Base Monthly Rent applicable to each extension period shall be 95% of the “Fair Market Rent” for the Leased Premises. For purposes
hereof, “Fair Market Rent” shall mean the initial Base Monthly Rent for each extension period and any escalations thereto, as determined with reference to the then-prevailing rates for recently negotiated direct leases (i.e., not
subleases) in comparable 2007 or newer steel frame buildings of four (4) or more stories in the cities of Santa Clara or Sunnyvale (but not taking into account Tenant’s furniture, fixtures, or equipment, or any above-standard tenant
improvements made by Tenant at its sole cost), pursuant to the process described below. Except to the extent set forth in a separate written agreement between Landlord and such broker, no leasing commissions shall be due or payable to any broker
retained by Tenant with regard to this Lease for any Extension Period. 
 15.3 Tenant’s Election. Within thirty (30) days
after receipt of Tenant’s notice of exercise, Landlord shall notify Tenant in writing of Landlord’s estimate of the Base Monthly Rent for the applicable extension period, based on the provisions of Paragraph 15.2 above. Within thirty
(30) days after receipt of such notice from Landlord, Tenant shall have the right either to (i) accept Landlord’s statement of Base Monthly Rent as the Base Monthly Rent for the applicable extension period; or (ii) elect to
arbitrate Landlord’s estimate of Fair Market Rent, such arbitration to be conducted pursuant to the provisions hereof. Failure on the part of Tenant to require arbitration of Fair Market Rent within such thirty (30) day period shall
constitute acceptance of the Base Monthly Rent for the applicable extension period as calculated by Landlord. If Tenant elects arbitration, the arbitration shall be concluded within ninety (90) days after the date of Tenant’s election,
subject to extension for an additional thirty (30) day period if a third arbitrator is required and does not act in a timely manner. To the extent that arbitration has not been completed prior to the expiration of any preceding period for which
Base Monthly Rent has been determined, Tenant shall pay Base Monthly Rent at a rate equal to 102.5% of the Monthly Base Rent due for the last month of the initial Lease Term or First Extension Period, as relevant, with the potential for an
adjustment to be made once Fair Market Rent is ultimately determined by arbitration. 
 15.4 Rent Arbitration. In the event of
arbitration, the judgment or the award rendered in any such arbitration may be entered in any court having jurisdiction and shall be final and binding between the parties. The arbitration shall be conducted and determined in the City and County of
Santa Clara in accordance with the then prevailing rules of JAMS or its successor for arbitration of commercial disputes except to the extent that the procedures mandated by such rules shall be modified as follows: 

(a) Tenant shall make demand for arbitration in writing within thirty (30) days after service of Landlord’s determination of Fair
Market Rent given under Paragraph 15.3 above, specifying therein the name and address of the person to act as the arbitrator on its behalf. The arbitrator shall be qualified as a real estate appraiser or broker familiar with the Fair Market Rent of
comparable buildings in the Santa Clara or Sunnyvale area who would qualify as an expert witness over objection to give opinion testimony addressed to the issue in a court of competent jurisdiction. Failure on the part of Tenant to make a proper
demand in a timely manner for such arbitration shall constitute a waiver of the right thereto. Within fifteen (15) days after the service of the demand for arbitration, Landlord shall give notice to Tenant, specifying the name and address of
the person designated by Landlord to act as arbitrator on its behalf who shall be similarly qualified. If Landlord fails to notify Tenant of the appointment of its arbitrator, within or by the time above specified, then the arbitrator appointed by
Tenant shall be the arbitrator to determine the issue. 
 (b) In the event that two arbitrators are chosen pursuant to Paragraph 15.4(a)
above, the arbitrators so chosen shall, within fifteen (15) days after the second arbitrator is appointed determine the Fair Market Rent. If the two arbitrators shall be unable to agree upon a determination of Fair Market Rent within such
fifteen (15) day period, they, themselves, shall appoint a third arbitrator, who shall be a competent and impartial person with qualifications similar to those required of the first two arbitrators pursuant to Paragraph 15.4(a). In the event
they are unable to agree upon such appointment within seven (7) days after expiration of such fifteen (15) day period, the third arbitrator shall be selected by the parties themselves, if they can agree thereon, within a further period of
fifteen (15) days. If the parties do not so agree, then either party, on behalf of both, may request appointment of such a qualified person by the then Presiding Judge of the California Superior Court having jurisdiction over the County of
Santa Clara, and the other party shall not raise any question as to such Judge’s full power and jurisdiction to entertain the application for and make the appointment. The three arbitrators shall decide the dispute if it has not previously been
resolved by following the procedure set forth below. 
 (c) Where an issue cannot be resolved by agreement between the two arbitrators
selected by Landlord and Tenant or settlement between the parties during the course of arbitration, the issue shall be resolved by the three arbitrators within fifteen (15) days of the appointment of the third arbitrator in accordance with the
following procedure. The arbitrator selected by each of the parties shall state in writing his determination of the Fair Market Rent supported by the reasons therefor with counterpart copies to each party. The arbitrators shall arrange for a
simultaneous exchange of such 

  
 48 

 
Building D 
 proposed resolutions. The role of the third arbitrator shall be to select which of the
two proposed resolutions most closely approximates his determination of Fair Market Rent. The third arbitrator shall have no right to propose a middle ground or any modification of either of the two proposed resolutions. The resolution he chooses as
most closely approximating his determination shall constitute the decision of the arbitrators and be final and binding upon the parties. 

(d) In the event of a failure, refusal or inability of any arbitrator to act, his successor shall be appointed by him, but in
the case of the third arbitrator, his successor shall be appointed in the same manner as provided for appointment of the third arbitrator. The arbitrators shall decide the issue within fifteen (15) days after the appointment of the third
arbitrator. Any decision in which the arbitrator appointed by Landlord and the arbitrator appointed by Tenant concur shall be binding and conclusive upon the parties. Each party shall pay the fee and expenses of its respective arbitrator and both
shall share the fee and expenses of the third arbitrator, if any, and the attorneys’ fees and expenses of counsel for the respective parties and of witnesses shall be paid by the respective party engaging such counsel or calling such witnesses.

 (e) The arbitrators shall have the right to consult experts and competent authorities to obtain factual information or
evidence pertaining to a determination of Fair Market Rent, but any such consultation shall be made in the presence of both parties with full right on their part to cross examine. The arbitrators shall render their decision and award in writing with
counterpart copies to each party. The arbitrators shall have no power to modify the provisions of this Lease. 
 ARTICLE 16 TELEPHONE SERVICE 

Notwithstanding any other provision of this Lease to the contrary: 

(i) Landlord shall have no responsibility for providing to Tenant any telephone equipment, including wiring, within the Leased
Premises or for providing telephone service or connections from the utility to the Leased Premises; and 
 (ii) Landlord
makes no warranty as to the quality, continuity or availability of the telecommunications services in the Building, and Tenant hereby waives any claim against Landlord for any actual or consequential damages (including damages for loss of business)
in the event Tenant’s telecommunications services in any way are interrupted, damaged or rendered less effective, except to the extent caused by the active gross negligence or willful misconduct of Landlord, its agents or employees. Tenant
accepts the telephone equipment (including, without limitation, the intra-building network cable (“INC”)) in its AS-IS condition, and Tenant shall be solely responsible for contracting with a reliable third party vendor to assume
responsibility for the maintenance and repair thereof (which contract shall contain provisions requiring such vendor to inspect the INC periodically (the frequency of such inspections to be determined by such vendor based on its experience and
professional judgment), and requiring such vendor to meet local and federal requirements for telecommunications material and workmanship). Landlord shall not be liable to Tenant and Tenant waives all claims against Landlord whatsoever, whether for
personal injury, property damage, loss of use of the Leased Premises, or otherwise, due to the interruption or failure of telephone services to the Leased Premises. 

(iii) All costs incurred by Landlord for the installation, maintenance, repair and replacement of telephone wiring in the
Building, if Landlord in its sole discretion elects to do so, shall be a Property Maintenance Cost. 
 ARTICLE 17 

RIGHT OF FIRST REFUSAL TO LEASE; 

RIGHT OF FIRST OFFER TO PURCHASE; RIGHT OF FIRST REFUSAL TO PURCHASE 

17.1 Right of First Refusal to Lease. 

(a) Provided that at the time Landlord would otherwise be obligated to deliver a ROFR Notice (as hereinafter defined), Tenant
is Aruba Networks Inc. (or a Permitted Transferee) and is then leasing the entire five (5) floors of the Leased Premises and has not received written notice from Landlord informing Tenant that it is in monetary or material non-monetary default
under this Lease which is then currently uncured, then after receiving or negotiating an Acceptable Proposal (as defined below) for any portion (the “Identified ROFR Space”) of the sixth (6th) floor of the Building, Landlord
shall deliver a written notice (the “ROFR Notice”) to Tenant and the terms of the Acceptable Proposal. Anything in this Lease to the contrary notwithstanding, Tenant shall not have the right to deliver Tenant’s Election Notice
(as hereinafter defined) during any period that Tenant is in a monetary or material non-monetary default under any of the terms, covenants or conditions of this Lease with respect to which it has received a written notice from Landlord if such
default remains uncured, and the time periods provided for herein shall not be tolled or extended during Tenant’s cure thereof. 

  
 49 

 Building D 
  

(b) Tenant shall notify Landlord in writing within nine (9) business days after receipt of the ROFR Notice of Tenant’s election to
lease the Identified ROFR Space on the economic terms set forth in the Acceptable Proposal (“Tenant’s Election Notice”). Tenant shall not have the right to lease less than the entire Identified ROFR Space. If any
proposal Landlord receives includes any space in any of the Other Buildings, such space in the Other Building(s) shall be deemed deleted from the Acceptable 

Proposal so that Tenant’s Election Notice shall apply only to the Identified ROFR Space. As used herein, the term “Acceptable
Proposal” means a lease proposal received from or negotiated with a bona fide, unaffiliated third party (whether or not executed) containing terms upon which Landlord is willing to lease the Identified ROFR Space to such third party. 

(c) Failure of Tenant to deliver Tenant’s Election Notice within the required time period (i) shall be deemed an election by Tenant
to not lease the Identified ROFR Space, Landlord shall then be free to lease the Identified ROFR Space to a third party in accordance with the economic terms set forth in the ROFR Notice or such terms as Landlord shall elect and Tenant shall have no
further rights to lease the Identified ROFR Space thereafter, and this Paragraph 17.1 shall terminate and be of no further force or effect; provided, however, that (i) Tenant’s rights under this Paragraph 17.1 shall continue for any
portion of the sixth (6th) floor of the Building contiguous to the Leased Premises (as the same may have previously been expanded) which was not referenced in the ROFR Notice, (ii) Tenant’s rights under this Paragraph 17.1 with
respect to the Identified ROFR Space shall continue to the extent such space becomes available for lease again during the Lease Term or any extension thereof and is contiguous to the Leased Premises (as the same may have previously been expanded),
and (iii) in the event that Landlord proposes to lease such Identified ROFR Space at a Net Effective Rental Rate that is less (on a per rentable square foot basis) than ninety percent (90%) of the Net Effective Rental Rate specified in the
ROFR Notice, Tenant’s rights under this Paragraph 17.1 shall be revived as to the Identified ROFR Space and Landlord shall deliver a revised ROFR Notice (the “Revised ROFR Notice”) offering such Identified ROFR Space to
Tenant at such proposed lower rate and Tenant shall have the right to lease such Identified ROFR Space on the terms set forth in such Revised ROFR Notice by notice to Landlord given within nine (9) business days after Tenant’s receipt
thereof. As used in this Agreement, the term “Net Effective Rental Rate” shall mean the net present value of the rent and additional rent payable under the ROFR Notice, taking into account any allowances and the fair market
value of any work to be performed by Landlord at its expense in connection with any such proposed transaction using a discount rate equal to the Prime Rate plus two percent (2%) as reported in the Wall Street Journal from time to time, or any
successor published from time to time as reasonably selected by Landlord. 
 (d) If Tenant delivers Tenant’s Election Notice within the
time period required herein, Tenant shall be bound and obligated to lease from Landlord, and Landlord shall be bound and obligated to lease to Tenant, the Identified ROFR Space on the terms set forth in the ROFR Notice, and for record-keeping
purposes, Landlord and Tenant shall enter into an amendment of this Lease to include the Identified ROFR Space within fifteen (15) business days after Landlord’s receipt of Tenant’s Election Notice. The economic terms (including,
without limitation, the amount of rent and the tenant improvement allowance, if any) shall be the terms set forth in the ROFR Notice, and conforming changes shall be made as necessary or desirable to increase the rentable square footage of the
Leased Premises, as well as to any other provisions that are a function of the rentable square footage of the Leased Premises (e.g., Tenant’s Building Share and Tenant’s Project Share, and actual number of parking spaces allocated to
Tenant based upon the ratio set forth in the “Parking” Paragraph of Article 1 above). If Tenant has received written notice from Landlord that Tenant is in a monetary or material non-monetary default under any of the terms, covenants or
conditions of this Lease and such default remains uncured after the expiration of the relevant cure period, Landlord shall have, in addition to all of Landlord’s other rights and remedies provided in this Lease, the right to terminate the right
of first refusal contained herein upon notice to Tenant. 
 17.2 Right of First Offer to Purchase. If Landlord is then owned by Menlo
Equities Development Company IX LLC and Beacon Santa Clara Campus Equity LLC (or another special purpose entity with the same beneficial ownership as Santa Clara Campus Property Owner I LLC) and it or they then own all of the Subject Buildings (as
defined below), and Tenant and/or any Tenant Affiliate has expanded into the entirety of Building E and is leasing and fully occupying both the Leased Premises and Building E, and provided that Tenant is not then in monetary or material non-monetary
default under this Lease beyond the applicable cure period, if any, expressly set forth in this Lease, then if and when Landlord, in its sole discretion, decides to market the Building, Building C, and Building E (the “Subject
Buildings”) for sale on a standalone basis, Landlord would provide an offering package and/or summary financial information to Tenant twenty (20) days (the “Purchase Negotiation Period”) prior to offering the
Subject Buildings for sale to third parties and not solicit or entertain offers from parties other than Tenant during Negotiation Period. Tenant acknowledges Landlord may choose not to sell the Subject Buildings at any time during the Negotiation
Period and/or marketing process. This right shall be personal to Aruba Networks, Inc. or a Permitted Transferee, applies only to a sale of all of the Subject Buildings only, and without limitation shall not apply in the event of (a) a sale of
the Project, (b) an other multi-building or multi-project portfolio sale, (c) a Property, multi-property, or Project recapitalization or financing, or (d) a larger capital markets transaction (e.g., a merger, consolidation,
reorganization, master 

  
 50 

 Building D 
  

limited partnership, REIT, UPREIT, etc.) involving the Property or the Project. In the event Landlord and Tenant, each in its sole discretion, reach agreement with respect to the purchase and
sale of the Subject Buildings, then by no later than the end of the Negotiation Period they shall enter into an “As-Is” Purchase and Sale Agreement, without representations or warranties other than those relating to authority, and
otherwise reflecting the terms agreed upon during the Negotiation Period. 
 17.3 Right of First Refusal to Purchase. If Landlord is
then owned by Menlo Equities Development Company IX LLC and Beacon Santa Clara Campus Equity LLC (or another special purpose entity with the same beneficial ownership as Santa Clara Campus Property Owner I LLC) and it then owns all of the Subject
Buildings (as defined below), and it receives an unsolicited offer to purchase the Subject Buildings only which Landlord desires to accept, and provided that Tenant is not in default under this Lease, Landlord shall provide a summary of the
pertinent economic terms of such offer (“Unsolicited Offer Summary”). Tenant shall notify Landlord in writing with seven (7) days after receipt of the Unsolicited Offer Summary of Tenant’s
election to purchase the Subject Buildings on the terms set forth in the Unsolicited Offer Summary (“Tenant’s Purchase Election Notice”). Failure of Tenant to deliver Tenant’s Purchase Election Notice within
the required time period shall be deemed an election by Tenant not to purchase the Subject Buildings. This right shall be personal to Aruba Networks, Inc., applies only to a sale of all of the Subject Buildings only, and without limitation shall not
apply in the event of (a) a sale of the Project, (b) an other multi-building or multi-project portfolio sale, (c) a Property, multi-property, or Project recapitalization or financing, or (d) a larger capital markets transaction
(e.g., a merger, consolidation, reorganization, master limited partnership, REIT, UPREIT, etc.) involving the Property or the Project. In the event Tenant delivers Tenant’s Purchase Election Notice within the time period required herein,
Landlord and Tenant, within ten (10) business days after Landlord’s receipt of Tenant’s Purchase Election Notice, shall enter into an “As-Is” Purchase and Sale Agreement, without representations or warranties other than
those relating to authority, and otherwise reflecting the terms of the Unsolicited Offer Summary. 
 17.4 Memorandum of Lease. 

(a) Concurrently with the execution and delivery of this Lease, the parties shall execute a short form memorandum in substantially the form
attached hereto as Exhibit K-1 (the “Memorandum of Lease”), and thereafter within thirty (30) days Landlord shall at its sole cost and expense cause such Memorandum of Lease to be recorded in the Official Records
of Santa Clara County, California. Tenant agrees that at the request of any lender or ground lessor, the subordination documents executed and delivered by Tenant pursuant to Paragraph 13.3 above shall include the subordination of such Memorandum of
Lease to the applicable deed of trust or ground lease. 
 (b) Within ten (10) business days after Landlord’s written request,
which request Landlord may make at any time during the last thirty (30) days of the Lease Term (as extended, if applicable), Tenant shall execute, have acknowledged, and deliver to Landlord a Termination of Memorandum of Lease in the form of
Exhibit K-2 attached hereto, whereupon Landlord shall be authorized to cause the same to be recorded in the Official Records of Santa Clara County, California, immediately upon or at any time after the expiration or earlier termination of
this Lease. Tenant’s obligation to execute and deliver such Termination of Memorandum of shall survive the expiration or earlier termination of this Lease. 

(c) From time to time within ten (10) business days after Landlord’s written request, which request Landlord may make during the
thirty (30) day period preceding any of Tenant’s rights set forth in this Article 17 lapsing or otherwise expiring, terminating, or becoming ineffective, or at any time after any of such rights have lapsed, terminated, or become
ineffective, Tenant or its successors or assigns claiming rights in this Article 17 shall promptly execute, have acknowledged, and deliver to the Landlord, a Termination of Certain Rights under Lease in the form of Exhibit K-3 attached
hereto, modified to specify those rights lapsing, terminating, or otherwise becoming ineffective, whereupon Landlord shall be authorized to cause the same to be recorded in the Official Records of Santa Clara County, California. Tenant’s
obligation to execute and deliver such Termination of Certain Rights under Lease shall survive the expiration or earlier termination of this Lease. 

[REMAINDER OF PAGE INTENTIONALLY LEFT BLANK] 

  
 51 

 Building D 
  

IN WITNESS WHEREOF, Landlord and Tenant have executed this Lease as of the respective dates below set forth with the intent to be legally bound
thereby as of the Effective Date of this Lease first above set forth. 
  

							
					TENANT:
			
					ARUBA NETWORKS, INC., a Delaware corporation
			
	Dated: April 14, 2015				By: /s/ Ava M.
Hahn                                         
                           
			
					Printed Name: Ava M. Hahn
			
					Title: General Counsel
			
	Dated: April 15, 2015				By: /s/ Henry D.
Bullock                                        
                    
			
					Printed Name: Henry D. Bullock
			
					Title: President
			
					LANDLORD:

  

							
					SANTA CLARA CAMPUS PROPERTY OWNER I LLC, a Delaware limited liability company
				
					By:		Santa Clara Campus Partners LLC,
							 a Delaware limited liability company,
 its
Sole Member

  

									
					
							By:		Menlo Equities Development Company IX LLC,
									 a California limited liability company,
 its
Manager

  

									
					
							By:		Menlo Equities V LLC,
									 a California limited liability company,
 its
Manager

  

									
					
							By:		Menlo Legacy Holdings L.P.,
									 a California limited partnership,
 its
Managing Member

  

									
				
	Dated: April 15, 2015						By: /s/ Henry D.
Bullock                                        
    
							Henry D. Bullock, President

  
 52 

 Building D 
  

SCHEDULE 2.1 
 EXISTING
TITLE ENCUMBRANCES 
  

	1.	General and special taxes and assessments for the fiscal year 2014-2015. 

  

			
	 First Installment:
		$71,816.69, OPEN
	 Penalty:
		$0.00
	 Second Installment:
		$71,816.69, OPEN
	 Penalty:
		$0.00
	 Tax Rate Area:
		07-014
	 A. P. No.:
		216-31-082

 (Affects Parcel D) 
  

	2.	General and special taxes and assessments for the fiscal year 2014-2015. 

  

			
	 First Installment:
		$63,835.47, OPEN
	 Penalty:
		$0.00
	 Second Installment:
		$63,835.47, OPEN
	 Penalty:
		$0.00
	 Tax Rate Area:
		07-014
	 A. P. No.:
		216-31-083

 (Affects Parcel E) 
  

	2A.	General and special taxes and assessments for the fiscal year 2014-2015. 

  

			
	 First Installment:
		$74,403.03, OPEN

 [REMAINDER OF PAGE INTENTIONALLY LEFT BLANK] 

  
 1 

 Building D 
  

 

			
	 Penalty:
		$0.00
	 Second Installment:
		$74,403.03, OPEN
	 Penalty:
		$0.00
	 Tax Rate Area:
		07-014
	 A. P. No.:
		216-31-084

 (Affects Parcel A) 
  

	2B.	General and special taxes and assessments for the fiscal year 2014-2015. 

  

			
	 First Installment:
		$70,130.88, OPEN
	 Penalty:
		$0.00
	 Second Installment:
		$70,130.88, OPEN
	 Penalty:
		$0.00
	 Tax Rate Area:
		07-014
	 A. P. No.:
		216-31-085

 (Affects Parcel B) 
  

	2C.	General and special taxes and assessments for the fiscal year 2014-2015. 

  

			
	 First Installment:
		$76,313.19, OPEN
	 Penalty:
		$0.00
	 Second Installment:
		$76,313.19, OPEN
	 Penalty:
		$0.00
	 Tax Rate Area:
		07-014
	 A. P. No.:
		216-31-086

 (Affects Parcel C) 
  

	3.	The lien of supplemental taxes, if any, assessed pursuant to Chapter 3.5 commencing with Section 75 of the California Revenue and Taxation Code. 

 

	4.	Matters in a document entitled “Declaration of Covenants, Conditions, and Restrictions for Oakmead Village”, recorded December 28, 1973 in Book 0704, Page 601, Official Records, including but not limited
to covenants, conditions, restrictions, easements, assessments, liens and charges. 

 Amended Number One was recorded
November 26, 1974 in Book B187, Page 387, Official Records. 
 Notice of Addition of Real Property was recorded December 30, 1974
in Book B227, Page 134, Official Records. 
 Amendment Number Two was recorded March 26, 1975 in Book B334, Page 85, Official Records.

 Further Notices of Addition of Real Property were recorded December 8, 1976 in Book C462, Page 325; June 30, 1977 in Book
C959, Page 583; and June 30, 1977 in Book C959, Page 598, all Official Records. 
 Assignment of Grantor’s (Declarant’s)
Rights by Sequoia Pacific Realco, a general partnership, to 
 Campeau Corporation, was recorded April 4, 1978 in Book D570, Page 591,
Official Records. 
 Third Amendment was recorded October 07, 1987 in Book K317, Page 1365, Official Records. 

Assignment of Grantor’s Rights by Campeau Corporation, to Kimball Small Properties, Inc., was recorded June 11, 1993 in Book M826,
Page 1687, Official Records. 
  

	5.	An easement for any and all city utilities, access and incidental purposes, recorded June 28, 1977 in Book C951, Page 196 of Official Records. 

 

			
	 In Favor of:
		City of Santa Clara, a municipal corporation
	 Affects:
		As described therein

  

	6.	The terms and provisions contained in the document entitled “Covenant Running with Land and Lien” recorded April 23, 1980 in Book F289, Page 290 of Official Records. 

  
 2 

 Building D 
  

 

	7.	The terms and provisions contained in the document entitled “Covenant and Environmental Restriction on Property and Termination of Previous Covenant and Restriction” recorded February 28, 2012 as
Instrument No. 21551692 of Official Records. 

 Any claim asserted by reason of the facts disclosed or alluded to in the
document entitled “Covenant and Environmental Restriction on Property and Termination of Previous Covenant and Restriction”, recorded February 28, 2012, as Instrument No. 21551692, Official Records. 

 

	8.	A deed of trust to secure an original indebtedness of $99,600,000 recorded July 12, 2012 as Document No. 21745844 of Official Records. 

 

			
	 Dated:
		July 12, 2012
	 Trustor:
		Santa Clara Campus Property Owner I LLC, a Delaware limited liability company
	 Trustee:
		American Securities Company, a California corporation
	 Beneficiary:
		Wells Fargo Bank, N.A.

 The above deed of trust states that it is a construction deed of trust. 

A document recorded October 17, 2012 as Document No. 21904821 of Official Records provides that the deed of trust or the obligation
secured thereby has been modified. 
  

	9.	This item has been intentionally deleted. 

  

	10.	A financing statement recorded July 12, 2012 as Document No. 21745845 of Official Records. 

  

			
	 Debtor:
		Santa Clara Campus Property Owner I LLC
	 Secured party:
		Wells Fargo Bank, N.A.

  

	11.	An easement shown or dedicated on the map of Parcel Map recorded October 17, 2012 on file in book 856, page 23 through 26, of Parcel Maps. 

For: waterline, underground electrical, sidewalk, bus stop, driveway access, recreation, traffic signal and incidental purposes. 

 

	12.	The terms, provisions and easement(s) contained in the document entitled “Declaration of Reciprocal Easements (Underground Utilities)” recorded October 17, 2012 as Document No. 21904819 of Official
Records. 

  

	13.	The terms, provisions and easement(s) contained in the document entitled “Declaration of Reciprocal Easements(Access)” recorded October 17, 2012 as Document No. 21904820 of Official Records.

  

	14.	Water rights, claims or title to water, whether or not shown by the public records. 

  

	15.	This item has been Intentionally deleted. 

  

	16.	Rights of parties in possession. 

  

	17.	An easement for any and all city utilities, access and incidental purposes, recorded December 18, 1974 in Book B213, Page 325 of Official Records. 

 

			
	 In Favor of:
		City of Santa Clara, a municipal corporation
	 Affects:
		As described therein

  

	18.	An easement for sidewalk and incidental purposes, recorded December 18, 1974 in Book B213, Page 348 of Official Records. 

  

			
	 In Favor of:
		City of Santa Clara, a municipal corporation
	 Affects:
		As described therein

  

	19.	An easement for landscape improvement and maintenance and incidental purposes, recorded March 13, 1975 as Document No. 4964044, Book B317, Page 80 of Official Records. 

 

			
	 In Favor of:
		City of Santa Clara, a municipal corporation
	 Affects:
		as described therein

  
 3 

 Building D 
  

 

	20.	An easement for any and all city utilities, access and incidental purposes, recorded April 23, 1975 in Book B374, Page 393 of Official Records. 

 

			
	 In Favor of:
		City of Santa Clara, a municipal corporation
	 Affects:
		As described therein

  

	21.	An easement for sidewalk and incidental purposes, recorded May 28, 1975 in Book B431, Page 623 of Official Records. 

  

			
	 In Favor of:
		City of Santa Clara, a municipal corporation
	 Affects:
		As described therein

  

	22.	An easement for pipeline for the transmission of nitrogen gas and incidental purposes, recorded April 29, 1976 in Book B998, Page 379 of Official Records. 

 

			
	 In Favor of:
		Air Products and Chemicals, Inc., a Delaware corporation
	 Affects:
		As described therein

 Document(s) declaring modifications thereof recorded November 16, 1976 in Book C414, Page 469 of Official
Records. 
 Document(s) declaring modifications thereof recorded January 15, 1980 in Book F83, Page 403 of Official Records. 

The interest of the Grantee therein has been assigned of record to Air Products Manufacturing Corporation, a Delaware corporation, by
instruments recorded October 24, 1983 in Book I008, Page 207, and February 7, 1984 in Book I291, Page 296 and April 3, 1984 in Book I429, Page 384, all of Official Records. 

 

	23.	An easement for any and all city utilities, access and incidental purposes, recorded June 28, 1977 in Book C951, Page 226 of Official Records. 

 

			
	 In Favor of:
		City of Santa Clara, a municipal corporation
	 Affects:
		As described therein

  

	24.	An easement for private underground storm drain and incidental purposes, recorded October 6, 1993 as Book N051, Page 1514 of Official Records. 

 

			
	 In Favor of:
		Garrett Drive, Inc., a Massachusetts Corporation
	 Affects:
		as described therein

  

	25.	The terms and provisions contained in the document entitled “stormwater treatment measures inspection and maintenance agreement” recorded May 10, 2013 as Document No. 22214357 of Official Records.

  

	26.	Any statutory lien for labor or materials arising by reason of a work of improvement, as disclosed by a notice of completion recorded November 26, 2013 as Document No. 22457850 of Official Records, which
reflects a completion date of November 19, 2013. 

  

	27.	An easement for underground electrical and incidental purposes, recorded November 20, 2014 as Document No. 22773897 of Official Records. 

 

			
	 In Favor of:
		City of Santa Clara, California, a chartered municipal corporation
	 Affects:
		as described therein

  
 4 

 Building D 
  

SCHEDULE 2.2(a) 

APPROVED PARKING AREA 
  

 

  
 1 

 Building D 
  

EXHIBIT A 
 SITE PLAN

  
 

 

  
 Exhibit A 

 Building D 
  

 
 EXCLUSIVE USE AREA = AREA DENOTED
BY RED LINES ABOVE 

  
 Exhibit B 

 Building D 
  

EXHIBIT B 
 FLOOR PLAN

  
 

 

  
 Exhibit B 

 Building D 
  

EXHIBIT C 
 RESERVED

  
 Exhibit C 

 Building D 
  

EXHIBIT D 
 WORK LETTER

 THIS TENANT WORK LETTER (“Work Letter”) sets forth the agreement of Landlord and Tenant with respect to the
improvements to be constructed in the Leased Premises, as defined in the Lease to which this Work Letter is attached as an exhibit. In the event of any inconsistency between the terms of this Work Letter and the terms of the Lease, the terms of the
Lease shall control. All defined terms used herein shall have the meanings set forth in the Lease, unless otherwise defined in this Work Letter. 

1. Landlord’s Work. 

(a) Landlord will construct the base building warm shell of the Building, which shall be a six-story, steel frame building containing the
components listed on Exhibit A-1 attached hereto (the “Warm Shell Components”), in accordance with the plans for the Building which are being developed by Landlord and which are subject to approval by the City of Santa
Clara (such plans, prior to approval by the City being defined herein as the “Interim Base Building Plans” and, after approval by the City being defined herein as the “Final Base Building Plans”), and
the Site Plan (which also remains subject to approval, and changes if any are required, by the City of Santa Clara), and in compliance with all Laws applicable thereto on the date the Building is substantially completed by Landlord (the
“Landlord’s Work”). The exterior architecture of the Building shall be substantially the same as Building C, but shall consist of six (6) stories rather than four (4) stories. Landlord shall provide
Tenant’s architect with a CAD file of the Final Base Building Plans upon submittal of same to the City of Santa Clara Building Department (the “Submittal Date”). 

(b) Landlord will deliver drafts of the Interim Base Building Plans to Tenant as the same are developed and revised, within three
(3) business days after each revision set is completed. Tenant shall have the right at any time on or before the Submittal Date to request changes to the Base Building Plans or plans for the Building-Specific Common Areas in accordance with
this Paragraph 1 (each Tenant-requested change to the Base Building Plans or plans for the Building-Specific Common Areas, a “TRC”). Within ten (10) business days of receipt of any TRC or as soon thereafter as is reasonably
practicable, Landlord shall respond to Tenant in writing to such TRC request with either (a) its reasonable disapproval of such request (which may be based on, among other things, such request reducing the quality or scope of the Base Building
Plans or any of the Warm Shell Components), or (b) its good faith estimate (each a “TRC Estimate”), if the TRC were incorporated into the Base Building Plans or plans for the Building-Specific Common Areas, of:
(A) the increase (if any) or decrease (if any) in cost to design and construct the Warm Shell Components or plans for the Building-Specific Common Areas, and (B) the increase (if any) in days to design and construct the Warm Shell
Components or plans for the Building-Specific Common Areas. If Landlord delivers a TRC Estimate, Tenant shall promptly approve (“TRC Approval”) or disapprove (“TRC Disapproval”) the same in writing to
Landlord and any increase in costs (which may be netted, but not below zero, against any decreases in costs) shall be paid directly by Tenant to Landlord (provided that, at Tenant’s election, up to an aggregate maximum of $5 per rentable square
foot of the increase in costs may deducted from the Tenant Improvement Allowance), and the increase in days shall constitute Tenant Delay for purposes of the Lease and this Work Letter and, accordingly, shall adjust Landlord’s Delivery Date on
a day for day basis. Tenant shall be responsible for any increases in days and increases in costs whether or not the TRC Estimate turns out to be accurate. In addition, regardless of whether Tenant approves or disapproves a TRC Estimate, Tenant
shall be responsible for the increases in days and increases in costs resulting from the TRC approval process described in this Paragraph 1, including but not limited to the increases in time and costs involved in preparing TRC Estimates and in the
approval/disapproval process (such costs being defined herein as “TRC Amounts”). 
 (c) Any TRC which has been
approved by Tenant pursuant to a TRC Approval shall be referred to herein as an “Approved TRC”. If Tenant fails to deliver notice of Tenant’s consent, or the withholding of Tenant’s consent, to the proposed TRC
Estimate within five (5) business days, Tenant shall be deemed to have disapproved the TRC Estimate in question. A “TRC Estimate” with respect to any change shall be Landlord’s reasonable estimate of the following:
(1) direct construction costs thereof, (2) related general contractor’s general conditions, overhead and general contractor’s other indirect costs thereof (with respect to which Landlord shall provide Tenant with adequate
supporting documentation for Tenant’s confirmation), (3) the general contractor’s fee, which shall be the same fee being paid by Landlord to Landlord’s general contractor for the construction of the Warm Shell Components or plans
for the Building-Specific Common Areas, (4) design, permitting, testing, inspecting, engineering (which shall be the same fees being paid by Landlord to the Landlord architects and engineers for the construction of the Warm Shell Components or
plans for the Building-Specific Common Areas) and other indirect costs to be at Landlord’s actual costs incurred (i.e., there will be no Landlord markup), (5) the credit (if any) resulting from any savings resulting from all TRCs, and
(6) any other third party costs directly related to the TRC reasonably incurred by Landlord. 

  
 Exhibit D 

 Building D 
  

2. Tenant Improvements. Tenant shall construct, furnish or install such improvements, equipment or fixtures as are necessary for
Tenant’s use and occupancy of the Leased Premises (collectively, the “Tenant Improvements”). Tenant shall complete construction of the Tenant Improvements for the entirety of the Leased Premises. Tenant shall also be
responsible for the cost of any alterations to the Building required as a result of the Tenant Improvements unless such alterations are required due to Landlord’s failure to build the Warm Shell Components in accordance with the Final Base
Building Plans or applicable Laws. Tenant has engaged and Landlord has approved Alex Ingram to manage the design and construction of the Tenant Improvements (“Tenant Improvement Project Manager”). Tenant shall cause all
drawings and specifications for the Tenant Improvements to be prepared by an architect selected by Tenant and reasonably approved by Landlord (“Tenant Improvement Architect”) and to be constructed by a general contractor
licensed in California, selected by Tenant, and reasonably approved by Landlord (“Tenant Improvement Contractor”). Tenant has engaged and Landlord has approved Devcon Construction Inc. to be the Tenant Improvement Contractor.
Landlord’s prior written consent, which shall not be unreasonably withheld, shall be required if Tenant desires to change its Tenant Improvement Architect, Tenant Improvement Contractor or Tenant Improvement Project Manager. Tenant shall
furnish to Landlord a copy of the executed contracts between Tenant and Tenant Improvement Architect, and Tenant and Tenant Improvement Contractor, covering all of Tenant’s obligations under this Work Letter. 

The Tenant Improvements shall be in conformity with drawings and specifications submitted to and approved by Landlord, which approval shall
not be unreasonably withheld or delayed, and shall be performed in accordance with the following provisions: 
 Tenant Improvement Space
Plans: Tenant shall prepare and submit to Landlord for its approval Tenant Improvement space plans (the “Tenant Improvement Space Plans”). Within five (5) business days after receipt of Tenant’s drawings
Landlord shall return one set of prints thereof with Landlord’s approval and/or suggested modifications noted thereon. If Landlord fails to respond within five (5) business days, then Tenant may send a notice to Landlord, which notice must
contain the following inscription, in 14 point font and bold faced lettering: “SECOND NOTICE DELIVERED PURSUANT TO WORK LETTER—FAILURE TO TIMELY RESPOND WITHIN FIVE (5) BUSINESS DAYS SHALL RESULT IN DEEMED
APPROVAL.” If Tenant sends such a notice, and Landlord fails to respond within five (5) business days after its receipt of same, the proposed drawings shall be deemed approved. If Landlord has approved Tenant’s drawings subject to
modifications, such modifications shall be deemed to be acceptable to and approved by Tenant unless Tenant shall prepare and resubmit revised drawings for further consideration by Landlord. If Landlord has suggested modifications without approving
Tenant’s drawings Tenant shall prepare and resubmit revised drawings. All revised drawings shall be submitted, with changes highlighted, to Landlord, and Landlord shall approve or disapprove such revised drawings within five (5) business
days following receipt of the same. Landlord shall be provided with a copy of Tenant’s preliminary floor plan and associated CAD files as a condition to receiving reimbursement. Notwithstanding anything herein to the contrary, Landlord may only
object to such Tenant Improvement Space Plans if they present a Design Problem. As used in this Work Letter and in the Lease, the term “Design Problem” means that the proposed alteration, Tenant Improvements, or other work
would cause an adverse effect on the structural aspects of the Building or Building Systems, trigger any obligation of Landlord to make the Building comply with Laws (unless Tenant pays for the cost of such compliance), vitiate or otherwise reduce
any warranty for Landlord’s benefit with respect to the Building or Project, increase the cost of Landlord’s maintenance or repair costs with respect to the Building or Project unless such costs are paid by Tenant as billed by Landlord,
conflict with applicable codes or other Laws, affect the exterior appearance of the Building, or increase the cost of construction, or delay completion, of the Landlord’s Work. 

Tenant Improvement Design Development Plans: Tenant shall prepare and submit to Landlord for its approval Tenant Improvement design
development plans (“Tenant Improvement Design Development Plans”). Within five (5) business days after receipt of Tenant’s drawings Landlord shall return one set of prints thereof with Landlord’s approval
and/or suggested modifications noted thereon. If Landlord fails to respond within five (5) business days, then Tenant may send a notice to Landlord, which notice must contain the following inscription, in 14 point font and bold faced lettering:
“SECOND NOTICE DELIVERED PURSUANT TO WORK LETTER—FAILURE TO TIMELY RESPOND WITHIN FIVE (5) BUSINESS DAYS SHALL RESULT IN DEEMED APPROVAL.” If Tenant sends such a notice, and Landlord fails to respond within five
(5) business days after its receipt of same, the proposed drawings shall be deemed approved. If Landlord has approved Tenant’s drawings subject to modifications, such modifications shall be deemed to be acceptable to and approved by Tenant
unless Tenant shall prepare and resubmit revised drawings for further consideration by Landlord. If Landlord has suggested modifications without approving Tenant’s drawings Tenant shall prepare and resubmit revised drawings for consideration by
Landlord. All revised drawings shall be submitted, with changes highlighted, to Landlord following Landlord’s return to Tenant of the drawings 

  
 Exhibit D 

 Building D 
  

originally submitted, and Landlord shall approve or disapprove such revised drawings within five (5) business days following receipt of the same. Notwithstanding anything herein to the
contrary, Landlord may only object to such Tenant Improvement Design Development Plans if they present a Design Problem. 
 Tenant
Improvement Working Drawings: Tenant shall prepare and submit to Landlord for its approval Tenant Improvement working drawings (“Tenant Improvement Working Drawings”) including mechanical, electrical, and plumbing plans
(“MEP”). Within five (5) business days after receipt of Tenant’s drawings Landlord shall return one set of prints thereof with Landlord’s approval and/or suggested modifications noted thereon. If Landlord fails to
respond within five (5) business days, then then Tenant may send a notice to Landlord, which notice must contain the following inscription, in 14 point font and bold faced lettering: “SECOND NOTICE DELIVERED PURSUANT TO WORK
LETTER—FAILURE TO TIMELY RESPOND WITHIN FIVE (5) BUSINESS DAYS SHALL RESULT IN DEEMED APPROVAL.” If Tenant sends such a notice, and Landlord fails to respond within five (5) business days after its receipt of same, the
proposed drawings shall be deemed approved. If Landlord has approved Tenant’s drawings subject to modifications, such modifications shall be deemed to be acceptable to and approved by Tenant unless Tenant shall prepare and resubmit revised
drawings for further consideration by Landlord. If Landlord has suggested modifications without approving Tenant’s drawings Tenant shall prepare and resubmit revised drawings for consideration by Landlord. All revised drawings shall be
submitted, with changes highlighted, to Landlord following Landlord’s return to Tenant of the drawings originally submitted, and Landlord shall approve or disapprove such revised drawings within five (5) business days following receipt of
the same. Notwithstanding anything herein to the contrary, Landlord may only object to such Tenant Improvement Working Drawings if they present a Design Problem. 

Final Tenant Improvement Plans: Tenant shall submit the approved Tenant Improvement Working Drawings to the Santa Clara Building
Department for a Tenant Improvement building permit prior to the commencement of such work. The Tenant Improvement Working Drawings as modified by the City of Santa Clara are defined herein as the “Final Tenant Improvement Plans.”
Prior to commencing construction, Tenant shall deliver to Landlord a copy of the City of Santa Clara building permit for the Final Tenant Improvement Plans. 

Any material changes to the Final Tenant Improvement Plans shall be subject to Landlord’s prior written approval, which shall not be
unreasonably withheld. As used herein, the term “Material Changes” shall mean: a change to the Final Tenant Improvement Plans that exceeds Two Hundred Thousand Dollars ($200,000) in cost or could reasonably be expected to
cause a Design Problem. 
 Subject to Landlord’s review and approval of all applicable plans and specifications, Tenant shall have the
right to: (a) install communication conduit between the Building and Building C; (b) specify, purchase, and utilize its own cosmetic and/or decorative materials including, but not limited to, floor coverings, paint, and wall coverings;
(c) make floor cores consistent with normal office uses that do not interfere with the structural integrity of any floor; (d) install Tenant’s own security card access systems to the Leased Premises; and (e) secure the Leased
Premises during and after business hours. 
 Tenant acknowledges that it will engage the Tenant Improvement Architect, the Tenant
Improvement Project Manager, and the Tenant Improvement Contractor, and shall be solely responsible for the actions and omissions of its architects, engineers, contractors, and project/construction managers and for any loss, liability, claim, cost,
damage or expense suffered by Landlord or any other entity or person as a result of the acts or omissions of its architect, engineers or project/construction managers. Landlord’s approval of any of Tenant’s architects, engineers or
project/construction managers and of any documents prepared by any of them shall not be for the benefit of Tenant or any third party, and Landlord shall have no duty to Tenant or to any third parties for the actions or omissions of Tenant’s
architects, engineers or project/construction managers. Tenant shall indemnify and hold harmless Landlord from and against any and all losses, costs, damages, claims and liabilities arising from the actions or omissions of Tenant’s architects,
engineers and project/construction managers. 
 The Tenant Improvements shall be constructed by Tenant Improvement Contractor in accordance
with the Final Tenant Improvement Plans, in compliance with all of the terms and conditions of this Work Letter and the Lease, and with all applicable Laws and Restrictions. Tenant or the Tenant Improvement Contractor shall obtain a builder’s
risk policy of insurance in an amount and form and issued by a carrier reasonably satisfactory to Landlord, and its subcontractors shall carry worker’s compensation insurance for their employees as required by law. The builder’s risk
policy of insurance shall name Landlord as an additional insured and shall not be cancelable without at least thirty (30) days’ prior written notice to Landlord. 

Tenant shall notify Landlord of its intention to commence construction five (5) days prior to commencement and shall again notify
Landlord of actual commencement within one (1) business day 

  
 Exhibit D 

 Building D 
  

thereafter. Landlord shall have the right to post in a conspicuous location on the Building or the Leased Premises, as well as record with the County of Santa Clara, a Notice of
Nonresponsibility. Tenant shall provide Landlord with a copy of the City of Santa Clara building permit allowing for the construction of the Final Tenant Improvement Plans prior to commencement of construction of the Tenant Improvements. 

Tenant shall, and shall cause Tenant’s Project Manager to, use commercially reasonable efforts to cause construction of the Final Tenant
Improvement Plans to be performed in as efficient a manner as is commercially reasonable. All work to be performed inside or outside of the Building shall be coordinated with Landlord. Tenant and the Tenant Improvement Contractor shall conduct their
work and employ labor for the Tenant Improvements in such manner as to maintain harmonious labor relations. 
 Tenant, at Tenant’s sole
cost and expense, shall clear debris resulting from the Tenant Improvement construction as necessary so as not to interfere with the construction of the Landlord’s Work. No trash, or other debris, or other waste may be deposited at any time
outside the Building except in containers reasonably approved by Landlord. If so, Landlord may, after written notice to Tenant, remove it at Tenant’s expense, which expense shall equal the cost of removal plus ten percent (10%) of such
costs as a management fee. Storage of Tenant Improvement construction materials, tools and equipment shall be coordinated with Landlord’s contractor. Tenant shall reimburse Landlord on demand for the cost of repairing any damage to the Building
caused by Tenant Improvement Contractor and its subcontractors during the construction of the Tenant Improvements. Upon completion of the Tenant Improvements, Tenant shall cause the Building and the Common Areas to be clean and free from
construction debris resulting from Tenant’s Tenant Improvement construction. 
 Tenant shall submit to Landlord upon completion of the
Tenant Improvements a Certificate of Substantial Completion, AIA Document G704, by its Tenant Improvement Architect for the Final Tenant Improvement Plans, a copy of all final inspection cards for the Tenant Improvements signed by the appropriate
City of Santa Clara inspector and the Temporary Certificate of Occupancy from the City of Santa Clara. 
 Tenant shall submit to Landlord
two CDs containing copies of all Tenant Improvement as-built plans and specifications, or final field drawings covering all of the work in the Final Tenant Improvement Plans. 

Any minor work required for Tenant’s occupancy of the Leased Premises but not included in the Final Tenant Improvement Plans such as the
procurement and installation of furniture, fixtures, equipment, interior artwork and signage, shall not require Landlord approval but shall be installed in a good and workmanlike manner by Tenant. 

3. Project Costs. The costs and expenses of the development and construction of the Landlord’s Work and the Tenant Improvements
(“Project Costs”) (other than TRC Amounts as defined in Paragraph 1(b) above) shall be paid in accordance with this Paragraph 3. 

(a) Landlord’s Work. The costs and expenses of the development and construction of the Landlord’s Work shall be paid by
Landlord. 
 (b) Tenant Improvements. Unless specified otherwise herein, Tenant shall bear and pay the cost of the Tenant
Improvements (which cost shall include, without limitation, the costs of construction as provided for in the Tenant Improvement Contractor’s contract, the cost of permits, and all architectural, design, space planning, and engineering services
obtained by Tenant in connection with Tenant Improvements, office improvements, wiring and cabling costs, and cubicle costs; provided that, so long as Tenant is not in monetary or material non-monetary default under the Lease or this Work Letter,
Landlord shall contribute a maximum of $65 per rentable square foot, for an aggregate maximum of $13,314,4051 (the “Tenant Improvement Allowance”), but in no event more than $65
per square foot of the applicable space under construction, which shall be utilized only for building improvements to the Building (but a portion thereof up to a maximum of $5 per rentable square foot may be used for building improvements to the
portion of the Common Areas described in Paragraph 2(c) of the Lease), and for any related costs, including but not limited to design, engineering, construction, furniture and equipment appurtenant to the Leased Premises, cabling, project management
fees, moving expenses, and signage, and shall be available to Tenant only until the date which is twelve (12) months after the Lease Commencement Date (the “TI Allowance Deadline”), after which Landlord shall have no further
obligation to provide any portion of the Tenant Improvement Allowance. Landlord shall have no obligation to make disbursements of the Tenant Improvement Allowance at any time that Landlord has delivered written notice of a monetary or material
non-monetary default under the Lease or this Work Letter by Tenant until such default has been cured. Subject to such TI Allowance Deadline, and based 

 

	1 	Based upon the Leased Premises containing 204,837 rentable square feet of space, and subject to measurement and adjustment as described in the “Leased Premises” definition in Article 1 of the Lease.

  
 Exhibit D 

 Building D 
  

upon applications for payment prepared, certified and submitted by Tenant as described below, Landlord shall make progress payments from the Tenant Improvement
Allowance to Tenant in accordance with the provisions of this Paragraph 3 (but in no event more than $65 per square foot for the applicable space under construction), as follows: 

(i) Not later than the 25th day of each month Tenant shall submit applications for payment to Landlord in a form reasonably acceptable to
Landlord, including Tenant Improvement Contractor’s Application and Certification for Payment AIA G702 certified by Tenant Improvement Architect, certified as correct by an officer of Tenant and by Tenant’s architect, for payment of that
portion of the cost of the Tenant Improvements allocable to labor, materials and equipment incorporated in the Building or Common Areas during the period from the first day of the same month projected through the last day of the month. Each
application for payment shall set forth such information and shall be accompanied by such supporting documentation as shall be reasonably requested by Landlord, including the following: 

(A) Invoices and canceled checks. 

(B) Fully executed conditional lien releases in the form prescribed by law from the Tenant Improvement Contractor and all subcontractors and
suppliers furnishing labor or materials during such period and fully executed unconditional lien releases from all such entities covering the prior payment period. 

(C) Tenant Improvement Contractor’s worksheets showing percentages of completion. 

(D) Tenant Improvement Contractor’s certification as follows: 

“There are no known mechanics’ or materialmen’s liens outstanding at the date of this application for payment, all due and
payable bills with respect to the Building have been paid to date or shall be paid from the proceeds of this application for payment, and there is no known basis for the filing of any mechanics’ or materialmen’s liens against the Building
or the Property, and, to the best of our knowledge, waivers from all subcontractors are valid and constitute an effective waiver of lien under applicable law to the extent of payments that have been made or shall be made concurrently herewith.”

 (ii) On or before the 15th day following submission of the application for payment, so long as Tenant is not in default under the terms
of this Work Letter or the Leases, Landlord shall pay a share of such payment determined by multiplying the amount of such payment by a fraction, the numerator of which is the amount of the Tenant Improvement Allowance, and the denominator of which
is the sum of (i) estimated construction cost of all Tenant Improvement work and materials for the entire Leased Premises and Common Areas, and (ii) the estimated cost of all professional services, fees and permits in connection therewith.
Tenant shall pay the balance of such payment, provided that at such time as Landlord has paid the entire Tenant Improvement Allowance on account of such Tenant Improvement work, all billings shall be paid entirely by Tenant; provided, however, that
Landlord shall have no obligation to make disbursements of the Tenant Improvement Allowance at any time that Landlord has delivered written notice of a monetary or material non-monetary default under the Lease or this Work Letter by Tenant until
such default has been cured. If upon completion of the Tenant Improvement Work and payment in full to the Tenant Improvement Contractor, the architect and engineer, and payment in full of all fees and permits, the portion of the cost of the Tenant
Improvement Work, architects’ and engineers’ fees, permits and fees theretofore paid by Landlord is less than the Tenant Improvement Allowance, Landlord shall reimburse Tenant for costs expended by Tenant for Tenant Improvement work up to
the amount by which the Tenant Improvement Allowance exceeds the portion of such cost theretofore paid by Landlord. Landlord shall have no obligation to advance the Tenant Improvement Allowance to the extent it exceeds the total cost of the Tenant
Improvement Work. In no event shall Landlord have any responsibility for the cost of the Tenant Improvement Work in excess of the Improvement Allowance. Landlord shall have no obligation to make any payments to Tenant Improvement Contractor’s
material suppliers or subcontractors or to determine whether amounts due them from Tenant Improvement Contractor in connection with the Tenant Improvement work have, in fact, been paid. The foregoing shall not be read to prevent Tenant from curing
the applicable default and then being entitled to the applicable disbursement once the default is cured if such cure is completed within the applicable cure period, if any, expressly set forth in this Work Letter or the Lease. 

(c) Additional Allowance for Tenant Work. Upon Tenant’s written request made at least thirty (30) days prior to the Lease
Commencement Date, so long as Tenant is not in monetary or material non-monetary default under the Lease or this Work Letter, but as an increase in the Base Monthly Rent payable by Tenant, Landlord will provide an additional amount, to be added to
the Tenant Improvement Allowance and disbursed as provided with respect thereto in subparagraph 3(b) above, of 

  
 Exhibit D 

 Building D 
  

$15 per rentable square foot, for an aggregate maximum of $3,072,5552/ (the “Additional Tenant Improvement Allowance”), but in no event more than $15 per square foot of
the applicable space under construction. The amount of the Additional Tenant Improvement Allowance shall accrue interest at the per annum rate of six percent (6%), compounded monthly, from the date each portion thereof is contributed by Landlord,
and the total amount thereof (including accrued interest) shall be fully amortized in equal monthly installments, commencing on the later of (i) the Lease Commencement Date, and (ii) the first day of the first full calendar month following
the first to occur of (A) the final disbursement by Landlord of the Additional Tenant Improvement Allowance, and (B) the TI Allowance Deadline, and ending on the first day of the 132nd month of the Lease Term, utilizing a per annum rate of
six percent (6%), compounded monthly, and the amount of each monthly installment shall be added to and become a part of the Base Monthly Rent. 

(d) Test Fit Allowance. Landlord and Tenant acknowledge that Landlord has previously provided Tenant with a satisfactory test fit
allowance to be used by Tenant in the development of the Tenant Improvement Space Plans. 
 (e) Evidence of Completion of Improvement
Work. Upon the completion of the Improvement Work, Tenant shall: 
 (i) Submit to Landlord a detailed breakdown of Tenant’s final
and total construction costs, together with receipted evidence showing payment thereof, satisfactory to Landlord. 
 (ii) Submit to Landlord
all Tenant Improvement building permits signed off by the City and any certificate of occupancy received by Tenant for the Leased Premises. 

(iii) Submit to Landlord, electronically in .pdf format or zip drive, the as-built plans and specifications or final field drawings referred
to above. 
 4. Tenant Delay. For the purposes of this Work Letter and the Lease, “Tenant Delay” means any actual delay in
the Landlord’s completion of the Warm Shell Components and Building-Specific Common Areas in the Required Delivery Condition resulting from either: (i) Tenant’s failure to fulfill its obligation with respect to provide either
documents or approvals within the time periods specified therefor herein, (ii) any change orders or TRCs requested by Tenant, (iii) any matters specifically identified elsewhere in this Work Letter or in the Lease as Tenant delays, or
(iv) an act or omission of Tenant or any Tenant Parties which interferes with the progress of construction of the Building. In the event of any Tenant Delay the date upon which Substantial Completion of the Landlord’s Work is deemed to
have occurred shall be advanced by the cumulative duration of such Tenant Delays, and the Delivery Date shall be deemed to have occurred in advance of the actual delivery date as a sole and direct result of the cumulative duration of such Tenant
Delays. A Tenant Delay shall not be deemed to have commenced until Landlord has provided written notice to Tenant that a Tenant Delay is occurring. With respect to any changes to the Warm Shell Components requested by Tenant, Landlord hereby
notifies Tenant that such request will result in a Tenant Delay, and Tenant agrees that this notice satisfies the requirement for written notice set forth in the previous sentence; provided, however, that upon completion of the TRC Estimate,
such TRC Estimate shall control over this sentence. 
 5. Unavoidable Tenant Improvement Delays. As used in this Work Letter, the
term “Unavoidable Tenant Improvement Delay” shall mean any delays Tenant experiences in constructing the Tenant Improvements which actually and directly, without intervening cause, materially and adversely affect
Tenant’s construction of the Tenant Improvements and prevent Tenant from completing the Tenant Improvements by the Lease Commencement Date as a result of acts of God or nature, delays in obtaining permits, or government shut-down. 

6. Landlord Delays. A “Landlord Delay” means the length of any actual delay in the permitting, construction or completion of
the Tenant Improvements or equipment to be installed by Tenant which actually and directly delays Substantial Completion of the Tenant Improvements beyond the date set forth in Paragraph 2.4(c) of the Lease (as such date may be extended pursuant to
Paragraph 2.4(c) of the Lease), which (a) is not caused by Force Majeure, and (b) is caused by (i) Landlord’s changes (other than TRCs) to the Final Base Building Plans as approved by the City of Santa Clara (provided such
changes, other than City-required changes, shall require Tenant’s approval, which shall not be unreasonably withheld); (ii) any other interference with Tenant’s Substantial Completion of the Tenant Improvements or placement of
furniture, fixtures or equipment in the Leased Premises caused by acts or omissions of Landlord or its agents or contractors; provided, however, that this clause (ii) shall be applicable only if Devcon is the Tenant Improvement Contractor, and
provided further that Tenant may not claim a Landlord Delay based upon Devcon’s or its subcontractors’ performance and completion of the Landlord’s Work. For the purposes of this Paragraph 6 only, the term “Substantial
Completion” means that the Tenant Improvements have been substantially completed pursuant to the details of the 
  

	2/ 	See footnote no. 1 

  
 Exhibit D 

 Building D 
  

Final Tenant Improvement Plans but for punch list items which don’t materially and adversely affect Tenant’s use of the Leased Premises and a
temporary certificate of occupancy for the Leased Premises has been issued by the City of Santa Clara. 
 7. Assignment of Rights Against
Architect, Contractor, etc. Tenant hereby assigns to Landlord on a non-exclusive basis any and all rights Tenant may have against the Tenant Improvement Contractor, the Tenant Improvement Architect, the Tenant Improvement Project Manager, and
any other of Tenant’s consultants, subcontractors, agents, etc., relating to the Tenant Improvements, without in any way obligating Landlord to pursue or prosecute such rights. Landlord acknowledges and agrees that such assignment is for
security purposes only, and is not an absolute or current assignment of such rights. If Tenant defaults in Tenant’s obligations pursuant to this Lease and, as a result thereof, Landlord successfully exercises Landlord’s rights pursuant to
the California Civil Code, then such assignment shall be an absolute assignment to Landlord of such rights, but until such time Tenant shall be the sole owner of such rights and may enforce them or not as Tenant deems appropriate, in Tenant’s
sole judgment. Tenant shall promptly cause the Tenant Improvement Contractor, the Tenant Improvement Architect, the Tenant Improvement Project Manager, and any other of Tenant’s consultants, subcontractors, agents, etc. (once each such person
has been engaged) to execute and deliver to Landlord a consent in the form of Exhibit B hereto, consenting to the foregoing assignment. 

8. Arbitration. All disputes under this Work Letter shall be submitted to arbitration under the office of JAMS in San Francisco,
California, and shall be conducted pursuant to its Streamlined Arbitration Rules and Procedures (and Landlord and Tenant hereby submit to arbitration of such matter by JAMS and the determination of such arbitrator shall be final and binding upon
both Landlord and Tenant). 

  
 Exhibit D 

 Building D 
  

EXHIBIT A-1 TO WORK LETTER 

The Campus @ 3333 Scott 

Building D – 6-Story ~ 240,000SF 

Landlord’s Warm Shell (Base Building & Core) 

GENERAL DESCRIPTION: Landlord’s shell and core will comply with all codes and regulations, including fire, building, Title 24 and ADA. Building
will have all components required for LEED Silver certification, at minimum. 
  

	 	•	 	The building will be a steel frame structure with glass and precast concrete window wall system with a curtain wall system at the entry. 

 

	 	•	 	Interior brace frames with exterior moment frames. 

  

	 	•	 	Glass/metal frame entry doors. 

  

	 	•	 	Roof Screen will be incorporated in the overall architectural design and included in the warm shell. 

  

	 	•	 	15’ floor-to-floor clearance on ground floor and 14’ on upper floors to allow for an 11’+/- ceiling height on the ground floor and a 10’ +/- finished ceiling on the upper floors. 

 

	 	•	 	Three exit stairs. 

  

	 	•	 	Finish of the upper floor elevator lobbies excluded; to be completed by Tenant as part of TIs. Main ground floor lobby will be included. 

 

	 	•	 	Fitness area provided on the ground floor of 3355 Scott Boulevard (Building A). 

 CONCRETE FLOORS 

 

	 	•	 	Floor flatness/levelness consistent with ASTM E1155/E 1155M. 

  

	 	•	 	The floors will be designed for structural loading capability that can accommodate the placement of furnishings, fixtures and equipment that is consistent with the needs of a typical office tenant—live load of
100psf. High density loads by Tenant are not anticipated. 

 EXTERIOR GLASS 

 

	 	•	 	Exterior glass Title 24 compliant, insulated, free from scratches, nicks, cracks, marring and the intrusion of weather. 

ELEVATORS 
  

	 	•	 	Four 3,500 lb capacity traction elevators that have a rated speed of 200 fpm provided. Side opening doors with 9’-3” cab finished ceiling height. 

 

	 	•	 	Cab floors finished to match the ground floor lobby. 

  

	 	•	 	All elevator cars, lobby call lanterns and call buttons are in compliance with all codes and regulations. 

  

	 	•	 	No service elevator provided. 

  

	 	•	 	No elevator cars security card readers; part of TIs. 

 PERIMETER CONDITIONS AND BUILDING CORE (ground floor
lobby, restrooms, elevators, stairwells and electrical rooms) 
  

	 	•	 	Lights, finished walls, ceiling and floor tile provided in restrooms and exit corridors only; lights and unfinished walls in electrical rooms. Toilet exhaust at restrooms included. IT closets are part of TI
construction. 

  

	 	•	 	Exit stairwells with painted walls, finished ceilings, handrails, lights and noise reducing epoxy sealed floors stairs and landings. 

 

	 	•	 	Exposed window wall system. Completed window assembly with painted metal frames. 

  

	 	•	 	Exterior building envelop insulation as per Title 24, roof insulation and firesafing are included. No drywall is included except in the core areas. Core walls are framed, drywalled and fire taped finish.

  

	 	•	 	Code compliant premium grade finished doors, complete with frame, trim and hardware, installed at all stairwells, toilet rooms and service areas. Finish to be mutually agreed to by Tenant and Landlord.

 PERIMETER WINDOW COVERINGS 

 

	 	•	 	Landlord’s architect shall specify a Mecho Shade for windows; to be mutually approved and installed by Tenant as part of TIs. 

TOILET ROOMS 
  

	 	•	 	Women’s and men’s toilet rooms designed and constructed in compliance with current code requirements, laws and recommendations for size and quantity, including the Americans with Disabilities Act/Title 24.
Tenant shall pay for any above code requirements. The design and finish shall be mutually approved by Landlord and Tenant and include the following: 

  

	 	•	 	Water (hot and cold) shall be provided for all toilet rooms. 

  

	 	•	 	Lavatory counters shall have high quality solid surface tops with recessed lavatories. 

  

	 	•	 	All faucets shall have auto-sensors. 

  

	 	•	 	Code required wet walls shall be finished with full height ceramic tile. 

  

	 	•	 	Includes floor drains. 

  
 Exhibit D 

 Building D 
  

 

	 	•	 	The ceilings shall be painted with semi-gloss paint. 

  

	 	•	 	Toilet partitions shall be floor mounted; baked enamel or P-lam. 

  

	 	•	 	Urinal partitions shall be wall mounted. 

  

	 	•	 	Low flow toilets and urinals shall be wall mounted in all restrooms. 

  

	 	•	 	Code compliant lighting only. 

  

	 	•	 	Showers in each ground floor men’s and women’s restroom. 

  

	 	•	 	All fixtures are porcelain and ADA compliant. 

  

	 	•	 	Accessories include: 

	 	•	 	Recessed seat cover dispenser 

  

	 	•	 	Recessed paper towel dispenser/waste receptacles 

  

	 	•	 	Recessed feminine napkin vendor 

  

	 	•	 	Recessed mounted roll toilet tissue dispensers 

  

	 	•	 	Handicap grab bar as required by code 

  

	 	•	 	Lavatory soap dispensers 

 WASTE WATER AND VENT SYSTEM (PLUMBING) 

 

	 	•	 	One 1” cold water line, two  3⁄4” hot water lines, a sanitary waste and vent on every floor for Tenant’s use. All
plumbing required for TIs, including any break areas, to be installed by Tenant as part of TIs. 

  

	 	•	 	An ADA accessible drinking water refrigerated fountain installed on each floor. Location determined by Tenant, subject to code requirements. 

HVAC SYSTEM 
  

	 	•	 	Sufficient capacity of roof mounted direct expansion VAV air cooled package units for a 240,000sf office building with energy management controls, horizontal roof duct connections to units and vertical shafts to each
floor provided by Landlord as part of the Base Building. Supply and exhaust ductwork and air outlets for warm shell “core” areas such as the restrooms also provided as part of the Base Building. DDC system (with control wiring, sensors,
thermostats and control panels for core areas only) provided for the Base Building HVAC system only, with the availability and capacity for the addition of DDC controls for future tenant improvements. 

 

	 	•	 	Rooftop boiler and hot water line vertically distributed and valved to each floor included in the Base Building. 

  

	 	•	 	Low pressure system designed by Landlord’s mechanical engineer in accordance with industry standards for open office use. 

  

	 	•	 	Building designed for return air plenum. 

  

	 	•	 	Tenant to install all additional exhaust and HVAC systems related to TIs, including connecting to the base building energy management system. 

SUPPLEMENTAL and 24 hour HVAC 
  

	 	•	 	Supplied by Tenant in TI construction. Landlord to provide a rooftop equipment pad within Landlord’s roof screen area for Tenant’s supplemental HVAC units. 

ELECTRICAL AND POWER SYSTEM 
  

	 	•	 	Transformer and main switchboard with a house panel required for 277/480 volt service provided per SVP specifications for a 240,000SF office building. Step-down transformers in electrical rooms on all floors. Landlord
provided switchgear and panels in the main electrical room sufficient to distribute power to accommodate the lobby, core, landscape lighting, HVAC, elevators and fire alarm. 

 

	 	•	 	Receptacles provided in the ground floor lobby, restrooms and exit corridors. 

  

	 	•	 	Downlights and specialty lighting provided in the ground floor lobby, restrooms and stairs/exit corridors. 

  

	 	•	 	Each building/tenant is to be separately metered. Landlord will coordinate with the utility companies to have meter installed at Landlord’s cost. Tenant to install submeters as needed and connect to the base
building energy management system. 

  

	 	•	 	No Emergency/Backup Power Supply and/or Generators supplied by Landlord. Landlord to provide conduit from electrical room to a site outside the building, to be mutually agreed upon, for future Tenant installed
generator. 

  

	 	•	 	Emergency elevator service not included. Elevators in fail safe mode and return to ground floor. 

  

	 	•	 	Egress lighting is battery back-up. 

 FIRE & LIFE SAFETY SYSTEMS 

 

	 	•	 	Major fire line throughout the buildings with sprinkler heads pointing up in unfinished interior space. Complete sprinkler assembly in finished ground floor lobby, restrooms and stairwells. Fire monitoring system for
base building with core; adequately sized to allow tenant to expand as part of TIs. 

  

	 	•	 	Monitoring provided for sprinklers, elevators and HVAC base building and core systems per code. Tenant to expand monitoring for TI. 

  

	 	•	 	Landlord to provide code required fire alarm sounding devices and strobe lights in base building and core areas. 

SECURITY ACCESS SYSTEMS 
  

	 	•	 	None provided. Supplied by Tenant in TI construction if desired by Tenant. Landlord to provide rough-in provisions at locations requested by Tenant. 

  
 Exhibit D 

 Building D 
  

TELECOMMUNICATION 
  

	 	•	 	Multi-telecommunication service providers to enter building through an MPOE via a joint trench. 

  

	 	•	 	An MPOE, feeder duct and service from the telephone company is provided to ground floor teledata/IT room adjacent to Landlord’s ground floor electrical room. Tenant responsible for distribution of its teledata/IT
within the building. 

  

	 	•	 	Landlord to provide four 4” conduits into the ground floor MPOE room from central telecom vaults which will connect to Landlord’s other buildings. 

 

	 	•	 	Landlord to provide roof top space and conduit to the MPOE room for Tenant’s satellite dish. Tenant responsible for installing its satellite dish. 

PARKING 
  

	 	•	 	Landlord to install surface parking and/or a parking garage sufficient to satisfy a parking ratio of 3.3 parking spaces per 1,000 rentable square feet of space constructed in the Project, and a minimum of 3.3 parking
spaces for each 1,000 net rentable square feet of Leased Premises shall continue to be located within the area depicted by a curved dotted line on Schedule 2.2(a) attached to the Lease. 

LANDSCAPE 
  

	 	•	 	Landlord to provide landscape and hardscape at all common areas surrounding the building and parking area and permanently installed seating and waste container, as shown on the attached site plan. 

 

	 	•	 	Bocce court and outdoor dining/seating areas as shown on attached site plan. 

  

	 	•	 	Bike lockers as per code/LEED. 

  

	 	•	 	Conduit from the main ground floor electrical room to two locations in the parking lot/garage for future tenant EV charging stations. 

 

	 	•	 	The landscaped areas to be planted such that areas containing flowers shall mature within one year of initial occupancy. 

  

	 	•	 	Areas planted with shrubs and trees shall mature within two years of initial occupancy. 

  

	 	•	 	All landscaped path of pedestrian travel areas to be lighted and irrigated with electrically controlled automatic systems. 

LOADING DOCK 
  

	 	•	 	No loading docks. A grade level loading area with double doors can be provided. 

  

	 	•	 	Exterior delivery areas and ground floor access other than the main lobby entry as shown on the attached site plan. 

  

	 	•	 	No trash compactor. Should Tenant desire a trash compactor, Landlord will install at Tenant’s costs. 

  
 Exhibit D 

 Building D 
  

EXHIBIT B TO WORK LETTER 

FORM OF CONSENT TO ASSIGNMENT 

This CONSENT TO ASSIGNMENT (“Consent”) is dated as of this      day of
            , 2015, by                     , a
                     ([“Tenant Improvement Architect”/“Tenant Improvement Contractor”/“Tenant Improvement
Project Manager”/Other Consultant]), in favor of                      Office Partners Holding Company LLC, a California
limited liability company (“Landlord”). 
 RECITALS 

A. Landlord and
                    , a                     
(“Tenant”) entered into that certain Lease Agreement dated as of             , 201     (the “Lease”) for premises located in the City of
                    , County of
                    , State of California, commonly known as or otherwise described as
                     Road, Suite     ,
                    , California; and 

B. Exhibit D to the Lease is a Work Letter pursuant to which Tenant has retained [Tenant Improvement Architect/Tenant Improvement
Contractor/Tenant Improvement Project Manager/Other Consultant]. 
 AGREEMENT 

NOW THEREFORE, for good and valuable consideration, the receipt and sufficiency of which
are hereby acknowledged, [Tenant Improvement Architect/Tenant Improvement Contractor/Tenant Improvement Project Manager/Other Consultant] hereby consents to the assignment effected by Paragraph 7 of the Work Letter. 

IN WITNESS WHEREOF, [Tenant Improvement Architect/Tenant Improvement Contractor/Tenant
Improvement Project Manager/Other Consultant] has executed this Consent as of the date first written above. 
  

							
	—		[TENANT IMPROVEMENT ARCHITECT/TENANT IMPROVEMENT CONTRACTOR/TENANT IMPROVEMENT
PROJECT MANAGER/OTHER CONSULTANT]
	—		 —

—
		By:		  

			—		Title:		  

	—		 —

—
		By:		  

			—		Title:		  

  
 Exhibit D 

 Building D 
  

EXHIBIT E 
 LEASE
COMMENCEMENT DATE CERTIFICATE 
 This LEASE COMMENCEMENT CERTIFICATE (“Certificate”) is made this
            day of             , 201_, by and between
            (“Landlord”), and             , a
            (“Tenant”), and is attached to and made a part of that certain Lease dated as of             , 201_,
by and between Landlord and Tenant (the “Lease”). 
 Landlord and Tenant hereby acknowledge and agree for all purposes of
the Lease that: 
  

	1.	Tenant has accepted possession of the Leased Premises and formally accepts the same and acknowledges that the Leased Premises are in the condition called for by the Lease (including the Work Letter). 

 

	2.	the Lease Commencement Date as defined in Paragraph 2.3 of the Lease is                     ,
201    , 

  

	3.	the rentable square footage of the Building is                     , 

 

	4.	the rentable square footage of the Leased Premises is                     , and 

 

	5.	Tenant’s Building Share is     .    %, 

  

	6.	Tenant’s Project Share is     .    %, 

  

	7.	the Tenant Improvement Allowance is $                    , 

 

	8.	the Additional Tenant Improvement Allowance is $                    , 

 

	9.	the number of parking spaces allocated to the Leased Premises is                     , and 

 

	10.	the schedule of Base Monthly Rent is: 

  

					
	 Period
	  	Base Monthly Rent*	 
	 Months 1-12
	  	$	                .    	  
	 Months 13-24
	  	$	                .    	  
	 Months 25-36
	  	$	                .    	  
	 Months 37-48
	  	$	                .    	  
	 Months 49-60
	  	$	                .    	  
	 Months 61-72
	  	$	                .    	  
	 Months 73-84
	  	$	                .    	  
	 Months 85-96
	  	$	                .    	  
	 Months 97-108
	  	$	                .    	  
	 Months 109-120
	  	$	                .    	  
	 Months 121-132
	  	$	                .    	  

 [NTD: Paragraphs 3 through 10 to be completed only if the Initial Measurement of the Building or the Initial Measurement of
the Leased Premises results in rentable square footages different than those set forth in Article 1 of the Lease] 
 IN WITNESS
WHEREOF, Landlord and Tenant have executed this Certificate on the date first above written. 
 TENANT: 

 

	
	ARUBA NETWORKS, INC., a Delaware corporation
	
	By:
                                         
                                         
          
	Printed Name:
                                         
                                 
	Title:                                     
                                         
             

	
	
	By:
                                         
                                         
          
	Printed Name:
                                         
                                 
	Title:                                     
                                         
             

  
 Exhibit E 

 Building D 
  

									
	LANDLORD:

  

			
	SANTA CLARA CAMPUS PROPERTY OWNER I LLC, a Delaware limited liability company
		
	 By:
		Santa Clara Campus Partners LLC, a Delaware limited liability company, its Sole Member

					
			
			   By:
		Menlo Equities Development Company IX LLC, a California limited liability company, its Manager

							
				
					 By:
		 Menlo Equities V LLC, a California limited liability company, its Manager

									
					
							  By:
		Menlo Legacy Holdings L.P., a California limited partnership, its Managing Member

															
						
											By:
                                        

											Henry D. Bullock, President

  
 Exhibit E 

 Building D 
  

EXHIBIT F 
 [RESERVED]

  
 Exhibit F 

 Building D 
  

EXHIBIT G 
 FORM OF LUMP
SUM PAYMENT AMENDMENT 
 AMENDMENT NO. __TO LEASE 

This AMENDMENT TO LEASE (“Amendment”) is dated as of this     day of
                , 201_ (the “Amendment Date”), by and between
                    LLC, a California limited liability company (“Landlord”), and
                    , a
                    (“Tenant”). 

RECITALS 
 A.
Landlord and Tenant entered into that certain Lease dated as of             , 201_ [as amended by that certain dated as of
            ] (collectively, the “Lease”) for premises located in the City of Santa Clara, County of Santa Clara, State of California, commonly known as or otherwise
described as Street, Suite             ,             , California, comprised of approximately rentable square feet of floor area
as more particularly described in the Lease; and 
 B. Landlord has exercised the Lump Sum Payment Option as defined in Paragraph
3.1(b) of the Lease. 
 C. Landlord and Tenant now desire to amend the Lease to set forth the on the terms and conditions set forth
herein. 
 AGREEMENT 

NOW THEREFORE, for good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, Landlord and Tenant
hereby agree as follows: 
 1. Definitions. All capitalized terms used in this Amendment but not otherwise defined shall have the meanings assigned
to them in the Lease. 
 2. Lump Sum Payment Date. The Lump Sum Payment Date is
                    , 201_. 
 3. Base Monthly
Rent Start Date. The Base Monthly Rent Start Date is                     , 201_. 

4. Abated Rent Lump Sum Payment. The amount of the Abated Rent Lump Sum Payment is
                     Dollars ($                ). 

5. Base Monthly Rent. The schedule of Base Monthly Rent, as set forth in Article 1 of the Lease, is hereby amended in its entirety to read as follows:

  

					
	 Period
	  	Base Monthly Rent	 
	 [Months __-__
	  	$	0.00	  
	 Months __**-12
	  	$	594,027.30	] 
	 Months 13-24
	  	$	594,027.30	  
	 Months 25-36
	  	$	607,392.91	  
	 Months 37-48
	  	$	621,059.25	  
	 Months 49-60
	  	$	635,033.09	  
	 Months 61-72
	  	$	649,321.33	  
	 Months 73-84
	  	$	663,931.06	  
	 Months 85-96
	  	$	678,869.51	  
	 Months 97-108
	  	$	694,144.08	  
	 Months 109-120
	  	$	709,762.32	  
	 Months 121-132
	  	$	725,731.97	  

 *Based upon the Leased Premises containing 204,837 rentable square feet of space, and subject to measurement
as described in the “Leased Premises” definition in the Lease, and adjustment. 
 **[DRAFTING NOTE: COMPLETE TO CORRESPOND WITH BASE MONTHLY RENT
START DATE AND CONFORM THE FIRST ROW IN THE SCHEDULE; IF BASE MONTHLY RENT START DATE IS MONTH 1, DELETE THE FIRST ROW IN THE SCHEDULE.] 

  
 Exhibit G 

 Building D 
  

6. Ratification. The Lease, as amended by this Amendment, is hereby ratified by Landlord and Tenant and Landlord and Tenant hereby agree that the Lease,
as so amended, shall continue in full force and effect. 
 7. Miscellaneous. 

7.1 Voluntary Agreement. The parties have read this Amendment and the mutual releases contained in it, and on the advice of counsel they
have freely and voluntarily entered into this Amendment. 
 7.2 Attorney’s Fees. If either party commences an action against the
other party arising out of or in connection with this Amendment, the prevailing party shall be entitled to recover from the non- prevailing party, reasonable attorney’s fees and costs of suit. 

7.3 Successors. This Amendment shall be binding on and inure to the benefit of the parties and their successors. 

7.4 Counterparts. This Amendment may be signed in two or more counterparts. When at least one such counterpart has been signed by each
party, this Amendment shall be deemed to have been fully executed, each counterpart shall be deemed to be an original, and all counterparts shall be deemed to be one and the same agreement. 

IN WITNESS WHEREOF, Landlord and Tenant have executed this Amendment as of the date first written above. 

TENANT: 
  

	
	ARUBA NETWORKS, INC., a          corporation
	
	By:                                     
                                         
      
	Printed
Name:                                        
                          
	Title: President
	
	By:                                     
                                         
      
	Printed
Name:                                        
                          
	Title: Chief Financial
Officer                                        
    
	
	LANDLORD:

  

			
	SANTA CLARA CAMPUS PROPERTY OWNER I LLC, a Delaware limited liability company
		
	 By:
		 Santa Clara Campus Partners LLC,
 a Delaware
limited liability company,
 its Sole Member

					
			
			 By:
		 Menlo Equities Development Company IX LLC,

a California limited liability company,
 its Manager

							
				
					 By:
		 Menlo Equities V LLC, a

California limited liability company, its Manager

									
					
							  By:
		 Menlo Legacy Holdings L.P.,
 a California
limited partnership, its Managing Member

											
					
									By:                                   
           
									 Henry D. Bullock, President

  
 Exhibit G 

 Building D 
  

EXHIBIT H 
 BUILDING
SIGNAGE 
  
 

 

  
 Exhibit H 

 Building D 
  

EXHIBIT I 

SUBORDINATION, NONDISTURBANCE AND ATTORNMENT PROVISIONS 

RECORDING REQUESTED BY 
 AND WHEN RECORDED MAIL TO:

 Wells Fargo Bank, National Association 
 CRE – San
Francisco - Gold (AU #02961) 
 600 California Street, 17th Floor 

San Francisco, CA 94108 
 Attn: Colleen King 

Loan No.              

 
  

 
 (Space Above For Recorder’s Use)

 SUBORDINATION AGREEMENT, ACKNOWLEDGMENT OF LEASE ASSIGNMENT, 

ESTOPPEL, ATTORNMENT AND NON-DISTURBANCE AGREEMENT 

(Lease to Security Instrument) 
  

	NOTICE:  	THIS SUBORDINATION AGREEMENT RESULTS IN YOUR SECURITY INTEREST IN THE PROPERTY BECOMING SUBJECT TO AND OF LOWER PRIORITY THAN THE LIEN OF SOME OTHER OR LATER SECURITY INSTRUMENT. 

THIS SUBORDINATION AGREEMENT, ACKNOWLEDGMENT OF LEASE ASSIGNMENT, ESTOPPEL, ATTORNMENT AND NON-DISTURBANCE AGREEMENT (“Agreement”) is
made [DATE] by and between [PROPERTY OWNER NAME], A(N) [ENTITY TYPE], OWNER(S) OF THE REAL PROPERTY HEREINAFTER DESCRIBED ([[collectively,]] “Mortgagor”), [TENANT NAME[ (“Tenant”) and Wells Fargo Bank,
National Association (collectively with its successors or assigns, “Lender”). 
 R E C I T A L S 

 

	A.	Pursuant to the terms and provisions of a lease dated [DATE OF LEASE] (“Lease”), Mortgagor granted to Tenant a leasehold estate in and to [[a portion of]] the property described on Exhibit
A attached hereto and incorporated herein by this reference (which property, together with all improvements now or hereafter located on the property, is defined as the “Property”). 

 

	B.	Mortgagor has executed, or proposes to execute, that certain Deed Of Trust (“Security Instrument”) securing, among other things, that certain Promissory Note dated [DATE OF NOTE]
(“Note”) in the principal sum of [LOAN AMOUNT ($NUMBERS)], in favor of Lender (“Loan”). The Security Instrument has been or will be recorded concurrently herewith in the real property records where the
Property is located. 

  

	C.	As a condition to Lender making the Loan secured by the Security Instrument, Lender requires that the Security Instrument be unconditionally and at all times remain a lien on the Property, prior and superior to all the
rights of Tenant under the Lease and that the Tenant specifically and unconditionally subordinate the Lease to the lien of the Security Instrument. 

  

	D.	Mortgagor and Tenant have agreed to the subordination, attornment and other agreements herein in favor of Lender. 

NOW THEREFORE, for valuable consideration and to induce Lender to make the Loan, Mortgagor and Tenant hereby agree for the benefit of Lender as follows: 

 

	(1)	SUBORDINATION. Mortgagor and Tenant hereby agree that: 

  

	 	1.	Prior Lien. The Security Instrument securing the Note in favor of Lender, and any modifications, renewals or extensions thereof (including, without limitation, any modifications, renewals or extensions with
respect to any additional advances made subject to the Security Instrument), shall unconditionally be and at all times remain a lien on the Property prior and superior to the Lease; 

  
 Exhibit I 

 Building D 
  

 

	 	2.	Subordination. Lender would not make the Loan without this agreement to subordinate; and 

  

	 	3.	Whole Agreement. This Agreement shall be the whole agreement and only agreement with regard to the subordination of the Lease to the lien of the Security Instrument and shall supersede and cancel, but only
insofar as would affect the priority between the Security Instrument and the Lease, any prior agreements as to such subordination, including, without limitation, those provisions, if any, contained in the Lease which provide for the subordination of
the Lease to a deed or deeds of trust or to a mortgage or mortgages. 

 AND FURTHER, Tenant individually declares, agrees and acknowledges for
the benefit of Lender, that: 
  

	 	4.	Use of Proceeds. Lender, in making disbursements pursuant to the Note, the Security Instrument or any loan agreements with respect to the Property, is under no obligation or duty to, nor has Lender represented
that it will, see to the application of such proceeds by the person or persons to whom Lender disburses such proceeds, and any application or use of such proceeds for purposes other than those provided for in such agreement or agreements shall not
defeat this agreement to subordinate in whole or in part; and 

  

	 	5.	Waiver, Relinquishment and Subordination. Tenant intentionally and unconditionally waives, relinquishes and subordinates all of Tenant’s right, title and interest in and to the Property to the lien of the
Security Instrument and understands that in reliance upon, and in consideration of, this waiver, relinquishment and subordination, specific loans and advances are being and will be made by Lender and, as part and parcel thereof, specific monetary
and other obligations are being and will be entered into which would not be made or entered into but for said reliance upon this waiver, relinquishment and subordination. 

 

	(2)	ASSIGNMENT. Tenant acknowledges and consents to the assignment of the Lease by Mortgagor in favor of Lender. 

  

	(3)	ESTOPPEL. Tenant acknowledges and represents that: 

  

	 	1.	Entire Agreement. The Lease constitutes the entire agreement between Mortgagor and Tenant with respect to the Property and Tenant claims no rights with respect to the Property other than as set forth in the
Lease; 

  

	 	2.	No Prepaid Rent. No deposits or prepayments of rent have been made in connection with the Lease, except as follows (if none, state “None”):    ; 

 

	 	3.	No Default. To the best of Tenant’s knowledge, as of the date hereof: (i) there exists no breach, default, or event or condition which, with the giving of notice or the passage of time or both, would
constitute a breach or default under the Lease; and (ii) there are no existing claims, defenses or offsets against rental due or to become due under the Lease; 

 

	 	4.	Lease Effective. The Lease has been duly executed and delivered by Tenant and, subject to the terms and conditions thereof, the Lease is in full force and effect, the obligations of Tenant thereunder are valid
and binding and there have been no [[further]] amendments, modifications or additions to the Lease, written or oral; and 

  

	 	5.	No Broker Liens. Neither Tenant nor Mortgagor has incurred any fee or commission with any real estate broker which would give rise to any lien right under state or local law, except as follows (if none, state
“None”):    . 

  

	(4)	ADDITIONAL AGREEMENTS. Tenant covenants and agrees that, during all such times as Lender is the Beneficiary under the Security Instrument: 

 

	 	1.	Modification, Termination and Cancellation. Tenant will not consent to any modification, amendment, termination or cancellation of the Lease (in whole or in part) except in accordance with its terms without
Lender’s prior written consent and will not make any payment to Mortgagor in consideration of any modification, termination or cancellation of the Lease (in whole or in part) other than in accordance with its terms, including but not limited to
amendments referenced in the Lease as necessary for the operation of the terms thereof without Lender’s prior written consent; 

  

	 	2.	Notice of Default. Tenant will notify Lender in writing concurrently with any notice given to Mortgagor of any default by Mortgagor under the Lease, and Tenant agrees that Lender has the right (but not the
obligation) to cure any breach or default specified in such notice within the time 

  
 Exhibit I 

 Building D 
  

	 	
periods set forth below and Tenant will not declare a default of the Lease, as to Lender, if Lender cures such default within fifteen (15) days from and after the expiration of the time
period provided in the Lease for the cure thereof by Mortgagor; provided, however, that if such default cannot with diligence be cured by Lender within such fifteen (15) day period, the commencement of action by Lender within such fifteen
(15) day period to remedy the same shall be deemed sufficient so long as Lender pursues such cure with diligence. 

  

	 	3.	No Advance Rents. Tenant will make no payments or prepayments of rent more than one (1) month in advance of the time when the same become due under the Lease. 

 

	 	4.	Assignment of Rents. Upon receipt by Tenant of written notice from Lender that Lender has elected to terminate the license granted to Mortgagor to collect rents, as provided in the Security Instrument, and
directing the payment of rents by Tenant to Lender, Tenant shall comply with such direction to pay and shall not be required to determine whether Mortgagor is in default under the Loan and/or the Security Instrument. In the event of such payments to
Lender, Mortgagor hereby releases Tenant from any claims Mortgagor may otherwise have for Tenant’s failure to pay rent to Mortgagor and agrees that any such payments shall be credited toward Tenant’s obligation to pay rent pursuant to the
terms of the Lease. 

  

	 	5.	Insurance and Condemnation Proceeds. In the event there is any conflict between the terms in the Security Instrument and the Lease regarding the use of insurance proceeds or condemnation proceeds with respect to
the Property, the provisions of the Security Instrument shall control. 

  

	(5)	ATTORNMENT. In the event of a foreclosure under the Security Instrument, Tenant agrees for the benefit of Lender (including for this purpose any transferee of Lender or any transferee of Mortgagor’s title in
and to the Property by Lender’s exercise of the remedy of sale by foreclosure under the Security Instrument) as follows: 

  

	 	1.	Payment of Rent. Tenant shall pay to Lender all rental payments required to be made by Tenant pursuant to the terms of the Lease for the duration of the term of the Lease; 

 

	 	2.	Continuation of Performance. Tenant shall be bound to Lender in accordance with all of the provisions of the Lease for the balance of the term thereof, and Tenant hereby attorns to Lender as its landlord, such
attornment to be effective and self-operative without the execution of any further instrument immediately upon Lender succeeding to Mortgagor’s interest in the Lease and giving written notice thereof to Tenant; 

 

	 	3.	No Offset. Lender shall not be liable: (i) for, nor subject to, any offsets or defenses which Tenant may have by reason of any act or omission of Mortgagor under the Lease, except by reason of any act or
omission continuing after foreclosure, or deed in lieu thereof, of which Lender had notice prior to foreclosure or deed in lieu thereof, and failed to cure within fifteen (15) days from and after the expiration of the time period provided in
the Lease for the cure thereof by Mortgagor, and which relates to the repair or maintenance of the Property; nor (ii) for the return of any sums which Tenant may have paid to Mortgagor under the Lease as and for security deposits, advance
rentals or otherwise, except to the extent that such sums are actually delivered by Mortgagor to Lender; and 

  

	 	4.	Subsequent Transfer. If Lender, by succeeding to the interest of Mortgagor under the Lease, should become obligated to perform the covenants of Mortgagor thereunder, then, upon any further transfer of
Mortgagor’s interest by Lender, all of such unaccrued obligations shall terminate as to Lender. 

  

	 	5.	Limitation on Lender’s Liability. Tenant agrees to look solely to Lender’s interest in the Property and the rent, income or proceeds derived therefrom for the recovery of any judgment against Lender,
and in no event shall Lender or any of its affiliates, officers, directors, shareholders, partners, agents, representatives or employees ever be personally liable for any such obligation, liability or judgment. 

 

	 	6.	No Representation, Warranties or Indemnities. Lender shall not be liable with respect to any representations, warranties or indemnities from Mortgagor, whether pursuant to the Lease or otherwise, including, but
not limited to, any representation, warranty or indemnity related to the use of the Property, compliance with zoning, landlord’s title, landlord’s authority, habitability or fitness for purposes or commercial suitability, or hazardous
wastes, hazardous substances, toxic materials or similar phraseology relating to the environmental condition of the Property or any portion thereof. 

  

	(6)	NON-DISTURBANCE. In the event of a foreclosure under the Security Instrument, so long as there shall then exist no breach, default, or event of default on the part of Tenant under the Lease, 

  
 Exhibit I 

 Building D 
  

	 	
Lender agrees for itself and its successors and assigns that the leasehold interest of Tenant under the Lease shall not be extinguished or terminated by reason of such foreclosure, but rather the
Lease shall continue in full force and effect in accordance with the terms thereof and Lender shall recognize and accept Tenant as tenant under the Lease subject to the terms and provisions of the Lease except as modified by this Agreement;
provided, however, that Tenant and Lender agree that the following provisions of the Lease (if any) shall not be binding on Lender: any option to purchase with respect to the Property; or any right of first refusal with respect to the Property; or
any provision regarding the use of insurance proceeds or condemnation proceeds with respect to the Property which is inconsistent with the terms of the Security Instrument. 

 

	(7)	MISCELLANEOUS. 

  

	 	1.	Remedies Cumulative. All rights of Lender herein to collect rents on behalf of Mortgagor under the Lease are cumulative and shall be in addition to any and all other rights and remedies provided by law and by
other agreements between Lender and Mortgagor or others. 

  

	 	2.	NOTICES. All notices, demands, or other communications under this Agreement and the other Loan Documents shall be in writing and shall be delivered to the appropriate party at the address set forth below (subject
to change from time to time by written notice to all other parties to this Agreement). All notices, demands or other communications shall be considered as properly given if delivered personally or sent by first class United States Postal Service
mail, postage prepaid, or by Overnight Express Mail or by overnight commercial courier service, charges prepaid, except that notice of Default may be sent by certified mail, return receipt requested, charges prepaid. Notices so sent shall be
effective three (3) Business Days after mailing, if mailed by first class mail, and otherwise upon delivery or refusal; provided, however, that non-receipt of any communication as the result of any change of address of which the sending party
was not notified or as the result of a refusal to accept delivery shall be deemed receipt of such communication. For purposes of notice, the address of the parties shall be: 

 

			
	Mortgagor:		[OWNER NAME
			STREE ADDRESS
			CITY, STATE ZIP]
		
			Attention: [CONTACT NAME]
	Tenant:		[TENANT NAME
			TENANT ADDRESS 1
			TENANT ADDRESS 2
			TENANT CITY, STATE ZIP]
		
			Attention: [TENANT CONTACT]
	Lender:		Wells Fargo Bank, National Association
			CRE – San Francisco Gold (AU #02961)
			420 Montgomery St., 6th Floor
			San Francisco, CA 94104
		
			Attention: Brett Kondrick
		
			Loan #: [LOAN NO.]
	With a copy to:		Wells Fargo Bank, National Association
			WLS Minneapolis Loan Center
			608 2nd Avenue South, 11th Floor
			Minneapolis, MN 55402
		
			Attention: James Fransen

 Any party shall have the right to change its address for notice hereunder to any other location within the
continental United States by the giving of thirty (30) days’ notice to the other party in the manner set forth hereinabove. 
  

	 	3.	Heirs, Successors and Assigns. Except as otherwise expressly provided under the terms and conditions herein, the terms of this Agreement shall bind and inure to the benefit of the heirs, executors,
administrators, nominees, successors and assigns of the parties hereto. 

  

	 	4.	Headings. All article, section or other headings appearing in this Agreement are for convenience of reference only and shall be disregarded in construing this Agreement. 

  
 Exhibit I 

 Building D 
  

 

	 	5.	Counterparts. To facilitate execution, this document may be executed in as many counterparts as may be convenient or required. It shall not be necessary that the signature of, or on behalf of, each party, or that
the signature of all persons required to bind any party, appear on each counterpart. All counterparts shall collectively constitute a single document. It shall not be necessary in making proof of this document to produce or account for more than a
single counterpart containing the respective signatures of, or on behalf of, each of the parties hereto. Any signature page to any counterpart may be detached from such counterpart without impairing the legal effect of the signatures thereon and
thereafter attached to another counterpart identical thereto except having attached to it additional signature pages. 

  

	 	6.	Exhibits, Schedules and Riders. All exhibits, schedules, riders and other items attached hereto are incorporated into this Agreement by such attachment for all purposes. 

IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the day and year first above written. 

NOTICE: THIS SUBORDINATION AGREEMENT CONTAINS A PROVISION WHICH ALLOWS THE PERSON OBLIGATED ON YOUR REAL PROPERTY SECURITY TO OBTAIN A LOAN A PORTION OF
WHICH MAY BE EXPENDED FOR OTHER PURPOSES THAN IMPROVEMENT OF THE LAND. 
 IT IS RECOMMENDED THAT, PRIOR TO THE EXECUTION OF THIS AGREEMENT, THE PARTIES
CONSULT WITH THEIR ATTORNEYS WITH RESPECT HERETO. 

  
 Exhibit I 

 Building D 
  

 

			
	“MORTGAGOR”
	
	[[SIGNATURE BLOCK FOR PROPERTY MORTGAGOR(S)]]
	
	“TENANT”
	
	[[SIGNATURE BLOCK FOR TENANT]]
	
	“LENDER”
	
	WELLS FARGO BANK,
	NATIONAL ASSOCIATION
		
	By:		  

	Name:		  

	Its:		  

 (IF DOCUMENT TO BE RECORDED, ALL SIGNATURES 

MUST BE ACKNOWLEDGED) 

  
 Exhibit I 

 Building D 
  

EXHIBIT A—DESCRIPTION OF PROPERTY 

[[TO BE ATTACHED]] 

  
 Exhibit I 

 Building D 
  

[[IF LEASE GUARANTY]] LEASE GUARANTOR’S CONSENT 

The undersigned (“Lease Guarantor”) consents to the foregoing [[Subordination Agreement]] [[Subordination Agreement; Acknowledgment of
Lease Assignment, Estoppel, Attornment and Non-Disturbance Agreement]] [[Acknowledgment of Lease Assignment, Estoppel, Attornment and Non-Disturbance Agreement]] and the transactions contemplated thereby and reaffirms its obligations under the lease
guaranty (“Lease Guaranty”) dated LEASE GUARANTY DATE. Lease Guarantor further reaffirms that its obligations under the Lease Guaranty are separate and distinct from Tenant’s obligations. 

AGREED: 
 Dated as
of:                         

“LEASE GUARANTOR” 
 [[SIGNATURE BLOCK FOR LEASE
GUARANTOR]] 
 (IF DOCUMENT TO BE RECORDED, ALL SIGNATURES 

MUST BE ACKNOWLEDGED) 

  
 Exhibit I 

 Building D 
  

EXHIBIT J 
 FORM OF
ESTOPPEL CERTIFICATE 
                     ,
20     
  

			
			 
			 
			 
			 
		
			 Re  
                                         
                               

			                                     
 , California

 Ladies and Gentlemen: 

Reference is made to that certain Lease, dated as of
                    , 20        , between
                    LLC, a California limited liability company (“Landlord”), and the undersigned (herein referred to as the
“Lease”). A copy of the Lease [and all amendment thereto] is[are] attached hereto as Exhibit A. At the request of Landlord in connection with
[                     State reasons for request for estoppel certificate
                    ], the undersigned hereby certifies to Landlord and to [state names of other parties requiring certification (e.g.,
lender, purchaser, investor)] (“Lender”/ “Purchaser”/ “Investor”) and each of your respective successors and assigns as follows: 

1. The undersigned is the tenant under the Lease. 

2. The Lease is in full force and effect and has not been amended, modified, supplemented or superseded except as indicated in Exhibit A. 

3. There is no defense, offset, claim or counterclaim by or in favor of the undersigned against Landlord under the Lease or against the
obligations of the undersigned under the Lease. The undersigned has no renewal, extension or expansion option, no right of first offer or right of first refusal and no other similar right to renew or extend the term of the Lease or expand the
property demised thereunder except as may be expressly set forth in the Lease. 
 4. All improvements to be constructed in the Leased
Premises by Landlord, if any, have been completed and accepted by Tenant, and any tenant construction or other allowances have been paid in full. [MODIFY OR DELETE, AS APPLICABLE, IF NOT CORRECT] 

5. The undersigned has no actual knowledge of any default now existing of the undersigned or of Landlord under the Lease, nor of any event
which with notice or the passage of time or both would constitute a default of the undersigned or of Landlord under the Lease. 
 6. The
undersigned has not received notice of a prior transfer, assignment, hypothecation or pledge by Landlord of any of Landlord’s interest in the Lease. 

7. The monthly rent due under the Lease is
$                    and has been paid through
                    , and all additional rent due and payable under the Lease has been paid through
                    . 
 8. The term of
the Lease commenced on                     , and expires on
                    , unless sooner terminated pursuant to the provisions of the Lease. Landlord has performed all work required by the Lease for the
undersigned’s initial occupancy of the demised property. 
 9. The undersigned has deposited the sum of
$                     with Landlord as security for the performance of its obligations as tenant under the Lease, and no portion of such deposit has
been applied by Landlord to any obligation under the Lease. 
 10. There is no free rent period pending, nor is Tenant entitled to any
Landlord’s contribution. [MODIFY OR DELETE, AS APPLICABLE, IF NOT CORRECT] 
 The above certifications are made to Landlord and [Lender/ Purchaser/
Investor] knowing that Landlord and [Lender/ Purchaser/ Investor] will rely thereon in [making a loan secured in part by an assignment of the Lease/ accepting an assignment of the Lease/ investing in Landlord/other]. Tenant’s “actual
knowledge” means the current, actual knowledge of the person executing this document on behalf of Tenant, without any duty of investigation (other than inquiry of the appropriate personnel of Tenant who have responsibility for administration of
the Lease in accordance with Tenant’s standard procedures applicable to its leasing program). 

  
 Exhibit K 

 Building D 
  

Tenant’s certifications above are made solely to estop Tenant from asserting against the recipients named therein (other than Landlord), facts or claims
contrary to those stated herein, and such certifications shall be binding on Tenant vis-à-vis the recipients named herein (other than Landlord) but shall not modify in any way, Tenant’s relationship, obligations or rights
vis-à-vis Landlord. 
 Very truly yours, 
  

	
	  

	 By:

	 Name:

	 Title:

  
 Exhibit K 

 Building D 
  

EXHIBIT K-1 

MEMORANDUM OF LEASE 
 RECORDING
REQUESTED BY 
 AND WHEN RECORDED MAIL TO: 
 Aruba Networks,
Inc. 
 1344 Crossman Avenue 
 Sunnyvale, California 

Attn: Mr. Michael Phelps 
 Senior Director of
Real Estate 
 and Facilities 
  

 
  

APN: 
 (Space Above For Recorder’s Use) 

Short-Term Lease 
 MEMORANDUM OF LEASE

 (3335 Scott Boulevard, Santa Clara, California) 

THIS MEMORANDUM OF LEASE (“Memorandum”) is entered into as of the          day of
April, 2015, by and between SANTA CLARA CAMPUS PROPERTY OWNER I LLC, a Delaware limited liability company (“Landlord”), and ARUBA NETWORKS, INC., a Delaware corporation (“Tenant”). 

1. Defined Terms; Exhibits. Unless otherwise set forth herein, all defined terms used in this Memorandum shall have the same meanings
ascribed thereto in the Lease (as defined below). All Exhibits referenced herein are attached hereto, and are incorporated herein by this reference. 

2. Premises. Landlord hereby leases to Tenant and Tenant hereby leases from Landlord, pursuant to the terms and conditions of that
certain Lease dated as of April             , 2015 (the “Lease”), those certain premises described in the Lease (the “Premises”), consisting of
approximately 204,837 rentable square feet of space, comprising the first through fifth floors of a six story building (the “Building”) known as Building D and located at 3335 Scott Boulevard in the City of Santa Clara, California,
situated on the real property more particularly described on Exhibit A to this Memorandum. Pursuant to the Lease, Landlord hereby also grants to Tenant the right to use the common areas of the Project in accordance with and as
described in the Lease. 
 3. Term. The term of the Lease (“Term”) is for a period of approximately one hundred
thirty-two (132) months, starting on the Commencement Date and ending one hundred thirty-two (132) months after the Lease Commencement Date, subject to adjustment as provided in the Lease. The Lease Commencement Date is expected to occur
on or about March 1, 2017, subject to adjustment as provided in the Lease. 

  
 Exhibit K 

 Building D 
  

4. Extension Options. Pursuant to the Lease, Landlord grants to Tenant two (2) consecutive options to extend the Term, each for a
period of five (5) years. 
 5. Right of First Refusal to Lease. Pursuant to the Lease, Landlord grants to Tenant an ongoing
right of first refusal to lease space on the sixth floor of the Building throughout the term of the Lease on terms and conditions more particularly described in Paragraph 17.1 of the Lease. 

6. Right of First Offer and Right of First Refusal to Purchase Buildings C, D, and E. Landlord has constructed another building in the
project known as Building C, and Landlord and Tenant have executed a lease for space in Building C. Landlord may, but is not obligated to, construct an additional building in the Project which building is described in the Lease as Building E. 

(a) In the event that (i) Landlord constructs Building E, (ii) Tenant is then leasing the entirety of Building E and the first
through fifth floors of Building D, (iii) Landlord is then SANTA CLARA CAMPUS PROPERTY OWNER I LLC and owns Buildings C, D, and E (the “Subject Buildings”), (iv) Tenant is not then in monetary or material non-monetary
default under this Lease beyond the applicable cure period expressly set forth in this Lease, (v) Landlord, in its sole discretion, decides to market the Subject Buildings for sale on a standalone basis, then Tenant will have a right of first
offer to purchase the Subject Buildings as more particularly described in Paragraph 17.2 of the Lease. 
 (b) In the event that
(i) Landlord constructs Building E, (ii) Tenant is then the Tenant under the Lease of Building D, (iii) Landlord is then SANTA CLARA CAMPUS PROPERTY OWNER I LLC and owns Buildings C, D, and E (the “Subject
Buildings”), (iv) Tenant is not then in default under the Lease, (v) Landlord, in its sole discretion, decides to market the Subject Buildings for sale on a standalone basis, then Tenant will have a right of first refusal to
purchase the Subject Buildings as more particularly described in Paragraph 17.3 of the Lease. 
 These rights referred to in this Paragraph
6 (which are fully described in Paragraphs 17.2 and 17.3 of the Lease) shall be personal to Aruba Networks, Inc. or a Permitted Transferee (as defined in the Lease), apply only to a sale of all of the Subject Buildings only, and without limitation
shall not apply in the event of (1) a sale of the Project, (2) an other multi-building or multi-project portfolio sale, (3) a Property, multi-property, or Project recapitalization or financing, or (4) a larger capital markets
transaction (e.g., a merger, consolidation, reorganization, master limited partnership, REIT, UPREIT, etc.) involving the Property or the Project. 

7. Lease Incorporated. All the other terms, conditions and covenants of the Lease are incorporated herein by this reference. This
Memorandum is intended simply to provide notice of certain of the terms and provisions of the Lease, and in no way amends, modifies, or is to be used to interpret the Lease or any portions thereof. In the event of a conflict between the provisions
of this Memorandum and the provisions of the Lease, the provisions of the Lease shall govern. 
 8. Counterparts. This Memorandum may
be executed in counterparts, each of which shall be an original but all of which together shall constitute one and the same agreement. This Memorandum is solely for notice and recording purposes and shall not be construed to alter, modify, expand,
diminish or supplement the provisions of the Lease. 
 [SIGNATURES ON FOLLOWING PAGE] 

  
 Exhibit K 

 Building D 
  

IN WITNESS WHEREOF, this Memorandum has been duly executed by the parties hereto as of the day and year first above written. 

 

					
	“LANDLORD”				LANDLORD:
			
					SANTA CLARA CAMPUS PROPERTY OWNER I LLC, A
					Delaware limited liability company

  

			
	 By:
		 Santa Clara Campus Partners LLC,
 a Delaware
limited liability company,
its Sole Member

 
					
			
			   By:
		Menlo Equities Development Company IX LLC,
a California limited liability company,
its Manager

 
							
				
					 By:
		 Menlo Equities V LLC,
a California limited liability company, its Manager

									
					
							  By:
		Menlo Legacy Holdings L.P.,
a California limited
partnership,
its Managing Member

  

					
	“TENANT”				ARUBA NETWORKS, INC.,
					a Delaware corporation

					
			
					By:
                                         
                   
					Name:
                                         
              
					Title:
                                         
                

  
 Exhibit K 

 Building D 
  

State of California 
 County of
                    } ss. 
 On
                     before me,
                    , Notary Public, personally
appeared                    , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the
within instrument and acknowledged to me that he/she executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted,
executed the instrument. 
 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.

 WITNESS my hand and official seal. 
  

					
	  
 Signature
				
					(seal)

  
 State of California 

County of             } ss. 

On                      before me,
                    , Notary Public, personally
appeared                    , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the
within instrument and acknowledged to me that he/she executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted,
executed the instrument. 
 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.

 WITNESS my hand and official seal. 
  

					
	  
 Signature
				
					(seal)

  
 Exhibit K 

 Building D 
  

EXHIBIT A 
 Legal
Description of Premises 

  
 Exhibit K 

 Building D 
  

EXHIBIT K-2 
 TERMINATION
OF LEASE AND MEMORANDUM OF LEASE 
 RECORDING REQUESTED BY 

AND WHEN RECORDED MAIL TO: 
 Menlo Equities LLC 

490 California Street, 4th Floor 

Palo Alto, California 94306 
 Attn: Henry Bullock/Rick Holmstrom

  
  

 
 APN: 

(Space Above For Recorder’s Use) 
 Short-Term
Lease 
 TERMINATION OF LEASE AND MEMORANDUM OF LEASE 

(3335 Scott Boulevard, Santa Clara, California) 

THIS TERMINATION OF LEASE AND MEMORANDUM OF (“Termination Agreement”) is entered into as of the
             day of                     ,
2            , by and between SANTA CLARA CAMPUS PROPERTY OWNER I LLC, a Delaware limited liability company (“Landlord”), and ARUBA NETWORKS, INC., a Delaware corporation
(“Tenant”). 
 Landlord and Tenant are parties to that certain (i) Lease dated as of April     ,
2015 for the building located at 3335 Scott Boulevard in the City of Santa Clara, California, situated on the real property more particularly described on Exhibit A to this Partial Termination Agreement (the “Lease”). In
connection with the Lease, Landlord and Tenant are also parties to that certain Memorandum of Lease dated as of April     , 2015, recorded on
                    , 2015 in the Official Records of Santa Clara County, California as Document No.
                     (the “Memorandum”). All of the terms and conditions of Lease were incorporated into the Memorandum. 

1. Unless otherwise set forth herein, all defined terms used in this Termination Agreement shall have the same meanings ascribed thereto in
the Lease. All Exhibits referenced herein are attached hereto, and are incorporated herein by this reference. 
 2. The Lease and the
Memorandum have expired or been terminated and are of no further force or effect. 
 3. Landlord and Tenant now desire to execute and record
this Termination Agreement in order to put the public on notice of the termination of the Lease. 
 4. This Termination Agreement may be
executed in counterparts, each of which shall be an original but all of which together shall constitute one and the same agreement. 

  
 Exhibit K 

 Building D 
  

IN WITNESS WHEREOF, this Partial Termination Agreement has been duly executed by the parties hereto as of the day and year first above written.

  

					
	“LANDLORD”				LANDLORD:
			
					SANTA CLARA CAMPUS PROPERTY OWNER I LLC, A
					Delaware limited liability company

  

			
	 By:
		 Santa Clara Campus Partners LLC,
 a Delaware
limited liability company,
its Sole Member

 
					
			
			   By:
		Menlo Equities Development Company IX LLC,
a California limited liability company,
its Manager

 
							
				
					 By:
		 Menlo Equities V LLC,
a California limited liability company,
its Manager

									
					
							  By:
		Menlo Legacy Holdings L.P.,
a California limited
partnership,
its Managing Member

  

					
	“TENANT”				ARUBA NETWORKS, INC.,
					a Delaware corporation

					
			
					By:
                                         
                   
					Name:
                                         
              
					Title:
                                         
                

  
 Exhibit K 

 Building D 
  

State of California 
 County of
            } ss. 
 On
            before me,             , Notary Public, personally
appeared            , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she
executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. 

I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. 

WITNESS my hand and official seal. 
  

					
	  
 Signature
				
					(seal)

 State of California 
 County of
            } ss. 
 On
            before me,             , Notary Public, personally
appeared            , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she
executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. 

I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. 

WITNESS my hand and official seal. 
  

					
	  
 Signature
				
					(seal)

  
 Exhibit K 

 Building D 
  

EXHIBIT A 
 Legal
Description of Premises 

  
 Exhibit K 

 Building D 
  

EXHIBIT K-3 
 TERMINATION
OF CERTAIN RIGHTS UNDER LEASE 
 RECORDING REQUESTED BY 

AND WHEN RECORDED MAIL TO: 
 Menlo Equities LLC 

490 California Street, 4th Floor 

Palo Alto, California 94306 
 Attn: Henry Bullock/Rick Holmstrom

  
  

 
  

			
	APN:		
			(Space Above For Recorder’s Use)

 Short-Term Lease 

TERMINATION OF CERTAIN RIGHTS UNDER LEASE 

(3335 Scott Boulevard, Santa Clara, California) 

THIS TERMINATION OF CERTAIN RIGHTS UNDER LEASE (“Partial Termination Agreement”) is entered into as of the
            day of             , 2    , by and between SANTA CLARA CAMPUS PROPERTY OWNER I LLC, a Delaware
limited liability company (“Landlord”), and ARUBA NETWORKS, INC., a Delaware corporation (“Tenant”). 

Landlord and Tenant are parties to that certain (i) Lease dated as of April     , 2015 for the building located at
3335 Scott Boulevard in the City of Santa Clara, California, situated on the real property more particularly described on Exhibit A to this Partial Termination Agreement (the “Lease”). In connection with the Lease,
Landlord and Tenant are also parties to that certain Memorandum of Lease dated as of April     , 2015, recorded on             , 2015 in the Official Records of Santa
Clara County, California as Document No.              (the “Memorandum”). All of the terms and conditions of Lease were incorporated into the Memorandum. 

1. Defined Terms; Exhibits. Unless otherwise set forth herein, all defined terms used in this Partial Termination Agreement shall have
the same meanings ascribed thereto in the Lease All Exhibits referenced herein are attached hereto, and are incorporated herein by this reference. 

2. Landlord granted to Tenant, pursuant to the Lease, certain purchase and lease rights more particularly described in the Lease. 

3. Tenant’s rights under Paragraph             and Paragraph
            of the Lease have terminated, and Landlord and Tenant hereby agree that each of such rights is now and hereafter shall be void and of no force or effect. 

4. Landlord and Tenant now desire to execute and record this Partial Termination Agreement in order to put the public on notice of the
termination of the Tenant’s rights under Paragraph             and Paragraph             of the Lease. 

5. Counterparts. This Partial Termination Agreement may be executed in counterparts, each of which shall be an original but all of
which together shall constitute one and the same agreement. 
 [SIGNATURES ON FOLLOWING PAGE] 

  
 Exhibit K 

 Building D 
  

IN WITNESS WHEREOF, this Partial Termination Agreement has been duly executed by the parties hereto as of the day and year first above written.

  

			
	 “LANDLORD”
		LANDLORD:
		
			SANTA CLARA CAMPUS PROPERTY OWNER I LLC,
			a Delaware limited liability company

  

			
		
	 By:
		Santa Clara Campus Partners LLC,
a Delaware limited liability company,
its Sole Member

 
					
			
			   By:
		Menlo Equities Development Company IX LLC,
a California limited liability company, its Manager

 
							
				
					 By:
		 Menlo Equities V LLC,
a California limited liability company,
its Manager

									
					
							  By:
		Menlo Legacy Holdings L.P., a California limited partnership, its Managing Member

					
	“TENANT”		ARUBA NETWORKS, INC.,
			a Delaware corporation
			 By:
		  

			 Name:
		  

			 Title:
		  

  
 Exhibit K 

 Building D 
  

State of California 
 County of
            } ss. 
 On
            before me,             , Notary Public, personally
appeared            , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she
executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. 

I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. 

WITNESS my hand and official seal. 
  

					
	  
 Signature
				
					(seal)

 State of California 
 County of
            } ss. 
 On
                     before me,
                        , Notary Public, personally
appeared                        , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are
subscribed to the within instrument and acknowledged to me that he/she executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the
person(s) acted, executed the instrument. 
 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is
true and correct. 
 WITNESS my hand and official seal. 
  

					
	  
 Signature
				
					(seal)

  
 Exhibit K 

 Building D 
  

EXHIBIT A 
 Legal
Description of Premises 

  
 Exhibit K

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00243-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00243-of-00352.parquet"}]]