Document:

Agreement for Engineering, Procurement and Construction Services

 Exhibit 10.1 
 EXECUTION COPY 
 AGREEMENT 
 For 
 ENGINEERING, PROCUREMENT, AND 
 CONSTRUCTION SERVICES 
 for

 42 - INCH SABINE PASS PIPELINE PROJECT 
 between 
 CHENIERE SABINE PASS PIPELINE COMPANY 
 and 
 WILLBROS ENGINEERS, INC.

 AGREEMENT 
 THIS AGREEMENT for Engineering, Procurement and Construction Services (the “Agreement”) is made and entered into effective as of this 1st day of February 2006 (“Effective Date”) by and
between Cheniere Sabine Pass Pipeline Company, a company organized under the laws of the State of Delaware (“Cheniere”), and Willbros Engineers, Inc., a company incorporated under the laws of the State of Delaware (“Willbros”).
Cheniere and Willbros are hereinafter sometimes referred to individually as a “Party” or collectively as the “Parties.” 
 WHEREAS, Cheniere desires to design, build, own and operate the 16.0-mile, 42-inch pipeline and related facilities to be constructed from the Cheniere liquefied natural gas terminal to a pipeline interconnect at Johnson’s Bayou,
all located entirely in Cameron Parish, Louisiana (as more fully described herein, the “Project”); and 
 WHEREAS, Willbros,
itself or through its Subcontractors or Vendors desires to provide engineering, procurement and construction services related to the Project; 
 NOW, THEREFORE, in consideration of the mutual covenants herein and for other good and valuable consideration, the receipt and sufficiency of which are acknowledged, Cheniere and Willbros hereby agree as follows: 
 1. SCOPE OF WORK 
  

	1.1	In close cooperation and coordination with Cheniere and subject to Paragraph 1.3 below, Willbros agrees to perform the Work, including all Project management, engineering,
procurement, construction and construction management for the Project, and provide all equipment, materials, supplies, labor workmanship, apparatus, machinery, tools, structures, inspection, manufacture, fabrication, installation, design, delivery,
transportation, storage and any incidental work reasonably inferable as required and necessary to complete the Project in accordance with Applicable Law, Applicable Codes and Standards and all other provisions of this Agreement. Without limiting the
generality of the foregoing, the Work is described in more particular detail in the Scope of Work set forth in Schedule “B”. 

  

	1.2	The Scope of Work is based upon and shall comply with the preliminary engineering developed by Cheniere’s other consultants and contractors and the FERC Certificate.

  

	1.3	Willbros shall not be responsible for and the Work excludes the Cheniere Provided Items identified in Paragraph 5.3 which are to be provided by Cheniere. 

2. PROJECT SCHEDULE 
 The
Work shall be performed in accordance with the dates set forth in the Project Schedule attached as Schedule “F”. 
  

 1 

 3. COMPENSATION 
 Willbros will submit invoices, and Cheniere shall pay Willbros the amounts due in accordance with Paragraph 5.4 of Schedule “A”. The sum
of the Cost of the Work, the Willbros Management Fee and the Contingency Costs is guaranteed by Willbros not to exceed Sixty-Seven Million Six Hundred Seventy Thousand Two Hundred Dollars ($67,670,200), subject to additions and deductions by Change
Order as provided herein (the “Guaranteed Maximum Price”), excluding Louisiana sales and use taxes applicable to permanent materials and equipment to be incorporated into the Project, which shall be reimbursed by Cheniere in accordance
with Paragraph 5.4.2 of Schedule “A”. Costs which would cause the Guaranteed Maximum Price to be exceeded shall be paid by Willbros without reimbursement by Cheniere. 
 4. GENERAL 
  

	4.1	The Agreement consists of this signed document (the “Signature Document”) and the following attached Schedules, which by this reference are incorporated herein and made a
part hereof: 

  

							
	 Schedule “A”    -
	  	Terms and Conditions
		  	Attachment I	  	-	  	Willbros Parent Guarantee
		  	Attachment II	  	-	  	Payment Bond, Performance Bond and Riders
		  	Attachment III	  	-	  	Mechanical Completion Certificate
		  	Attachment IV	  	-	  	Project Completion Certificate
		  	Attachment V	  	-	  	Start-up Certificate
		  	Attachment VI	  	-	  	Change Order Form
		  	Attachment VII	  	-	  	Approved Subcontractors and Vendors List
		  	Attachment VIII	  	-	  	Organizational Chart
		  	Attachment IX	  	-	  	Cheniere’s Health, Safety and Environmental Policies
		  	Attachment X	  	-	  	Lien and Claim Waivers
	Schedule “B”    -	  	Scope of Work for the Project
		  	Attachment I	  	-	  	Work Site
	Schedule “C”    -	  	Intentionally Omitted
	Schedule “D”    -	  	Applicable Codes and Standards, Drawings and Specifications
		  	Attachment I	  	-	  	Drawings
		  	Attachment II	  	-	  	Specifications
	Schedule “E”    -	  	Intentionally Omitted
	Schedule “F”    -	  	Project Schedule

  

	4.2	A reference in the Agreement to any of the Schedules shall, in addition, be considered a reference to any Attachments to said Schedules, and to all documents referred to in said
Schedules or Attachments. 

  

	4.3	 Any notice, demand, offer or other written instrument required or permitted to be given pursuant to this Agreement shall be in writing and signed by the Party
giving such notice 

  

 2 

	 	 
and shall be sufficient when delivered in person or sent by e-mail, by facsimile, or by certified or registered mail, to the other Party at the appropriate
address as follows: 

  

			
	If delivered to Cheniere:	  	If delivered to Willbros:
	Richard E. Keyser	  	Willbros Engineers, Inc.
	Cheniere Sabine Pass Pipeline	  	2087 East 71st Street
	717 Texas Avenue, Suite 3100	  	P.O. Box 701650
	Houston, Texas 77002	  	Tulsa, Oklahoma 74170
	Telephone: (832) 204-2284	  	Telephone: (918) 481-4163
	Fax: (713) 659-5459	  	Fax: (918) 493-3430
	Attention: Mr. Richard E. Keyser	  	Attention: Mr. Curtis E. Simkin
	E Mail: rkeyser@cheniere.com	  	E Mail: curt.simkin@willbros.com
		
	Copy to:	  	Copy to:
	Allan Bartz	  	Willbros Engineers, Inc.
	Cheniere Sabine Pass Pipeline	  	2087 East 71st Street
	717 Texas Avenue, Suite 3100	  	P.O. Box 701650
	Houston, Texas 77002	  	Tulsa, Oklahoma 74170
	Telephone: (713) 659-1361	  	Telephone: (918) 499-3706
	Fax: (713) 659-5459	  	Fax: (918) 499-3702
	Attention: Mr. Allan Bartz	  	Attention: Mr. Mike Reifel
	E Mail: abartz@cheniere.com	  	E Mail: mike.reifel@willbros.com

 Willbros or Cheniere may notify the other at any time of a change in, or addition to, the addresses
and/or persons to which communications should be sent. Notices, demands, offers or other written instruments shall be deemed to have been duly given on the date actually received by its intended recipient. 
 IN WITNESS WHEREOF, Cheniere and Willbros have executed duplicate originals of the Agreement, effective and binding as of the Effective Date. 
  

									
	 Witness
	 		 	 Cheniere Sabine Pass Pipeline Company

				
	/s/ Richard Keyser	 		 	 By:
	 	/s/ Robert Keith Teague
		 		 		 	 Title:
	 	President
		 		 		 	 Date:
	 	February 21, 2006
			
	 Witness
	 		 	 Willbros Engineers, Inc.

				
	/s/ Kevin R. Fox	 		 	 By:
	 	/s/ Curtis E. Simkin
		 		 		 	 Title:
	 	President
		 		 		 	 Date:
	 	February 1, 2006

  

 3 

 SCHEDULE “A” 
 TERMS AND CONDITIONS 
 TABLE OF CONTENTS 
  

			
	 1. DEFINITIONS
	  	A-2
	 2. WILLBROS’ OBLIGATIONS
	  	A-9
	 3. WILLBROS PERSONNEL AND EQUIPMENT
	  	A-12
	 4. WORK SITE RESPONSIBILITIES
	  	A-14
	 5. CHENIERE’S OBLIGATIONS
	  	A-15
	 6. WORK PLAN AND REPORTS
	  	A-20
	 7. INSPECTION AND TESTING
	  	A-22
	 8. COMPLETION AND START-UP
	  	A-23
	 9. CHANGES
	  	A-25
	 10. INDEMNITY, LIENS AND PATENTS
	  	A-26
	 11. INSURANCE
	  	A-30
	 12. WARRANTY
	  	A-34
	 13. TITLE TO THE WORK AND TO WORK PRODUCT, CONFIDENTIAL INFORMATION
	  	A-37
	 14. DISPUTE RESOLUTION
	  	A-40
	 15. SUSPENSION OF WORK
	  	A-42
	 16. TERMINATION AT CHENIERE’S CONVENIENCE
	  	A-43
	 17. TERMINATION BY CHENIERE FOR CAUSE
	  	A-44
	 18. TERMINATION BY WILLBROS
	  	A-45
	 19. WILLBROS’ OBLIGATIONS UPON SUSPENSION OR TERMINATION
	  	A-45
	 20. FORCE MAJEURE AND CHENIERE-CAUSED DELAY
	  	A-46
	 21. LIQUIDATED DAMAGES
	  	A-48
	 22. PUBLICITY RELEASES
	  	A-49
	 23. GOVERNING LAW
	  	A-49
	 24. GENERAL PROVISIONS
	  	A-49

  

					
	 ATTACHMENT I
	  	–	  	WILLBROS PARENT GUARANTEE
	 ATTACHMENT II
	  	–	  	PAYMENT BOND, PERFORMANCE BOND AND RIDERS
	 ATTACHMENT III
	  	–	  	MECHANICAL COMPLETION CERTIFICATE
	 ATTACHMENT IV
	  	–	  	PROJECT COMPLETION CERTIFICATE
	 ATTACHMENT V
	  	–	  	START-UP CERTIFICATE
	 ATTACHMENT VI
	  	–	  	CHANGE ORDER FORM
	 ATTACHMENT VII
	  	–	  	APPROVED SUBCONTRACTORS AND VENDORS LIST
	 ATTACHMENT VIII
	  	–	  	ORGANIZATIONAL CHART
	 ATTACHMENT IX
	  	–	  	CHENIERE’S HEALTH, SAFETY AND ENVIRONMENTAL POLICIES
	 ATTACHMENT X
	  	–	  	LIEN AND CLAIM WAIVERS

  

 A-1 

 SCHEDULE “A” 
 TERMS AND CONDITIONS 
 1. DEFINITIONS 
 The following terms shall have the meanings indicated for all purposes of the Agreement and the use of the singular includes the plural, and vice versa: 
  

	1.1	“AAA” has the meaning set forth in Paragraph 14.3. 

  

	1.2	“AAA Rules” has the meaning set forth in Paragraph 14.3. 

  

	1.3	“Actual Contract Amount” has the meaning set forth in Attachment I of the Letter Agreement. 

  

	1.4	“Agreement” has the meaning set forth in, and incorporates by reference the documents as stated in, Paragraph 4.1 of the Signature Document. 

  

	1.5	“Amendment” means any written modification of the Agreement, signed by both Cheniere and Willbros, other than Change Orders. 

  

	1.6	“Applicable Codes and Standards” means any and all codes, standards or requirements set forth herein (including Schedule “D”) or in any Applicable Law,
which codes, standards and requirements shall govern Willbros’ performance of the Work, as provided herein. In the event of an inconsistency or conflict between any of the Applicable Codes and Standards, the highest performance standard as
contemplated therein shall govern Willbros’ performance. 

  

	1.7	“Applicable Law” means all laws, statutes, ordinances, certifications, orders, decrees, injunctions, permits, agreements, rules and regulations, including any conditions
thereto, of any Governing Authority having jurisdiction over all or any portion of the Work Site or the Project or performance of all or any portion of the Work, or other legislative or administrative action of a Governing Authority, or a final
decree, judgment or order of a court which relates to the performance of Work hereunder or the interpretation or application of this Agreement, including (a) any and all permits, authorizations, certifications, or other approvals or orders,
(b) any Applicable Codes and Standards set forth in Applicable Law and (c) any Applicable Law related to (i) conservation, regulation, improvement, protection, pollution, contamination or remediation of the environment or
(ii) Hazardous Substances or any handling, treatment, storage, release, use and disposal or other disposition of Hazardous Substances, including the Comprehensive Environmental Response, Compensation and Liability Act (“CERCLA”).

  

	1.8	“Books and Records” has the meaning set forth in Paragraph 2.9. 

  

 A-2 

	1.9	“Catastrophic Storms” means storms which are listed by the National Oceanic and Atmospheric Administration as Billion Dollar U.S. Weather Disasters.

  

	1.10	“Change” means an addition, deletion, suspension of, revision or any other modification or Amendment to the Work. Adjustment to the Guaranteed Maximum Price, the
Preparation and Material Receipt Commencement Date, the Construction Commencement Date or the Scheduled Mechanical Completion Date shall in every instance constitute a Change. 

  

	1.11	“Change Order” means a document, in the form attached hereto as Attachment VI and signed by Cheniere and Willbros, issued on or after the Effective Date,
authorizing a Change to the Work, the Guaranteed Maximum Price, the Preparation and Material Receipt Commencement Date, the Scheduled Mechanical Completion Date, the Construction Commencement Date or any other material requirement under this
Agreement. 

  

	1.12	“Cheniere” has the meaning set forth in the introductory paragraph of the Signature Document. 

  

	1.13	“Cheniere’s Authorized Representative” means Richard E. Keyser, the person hereby authorized by Cheniere to act on its behalf on all matters pertaining to the
Agreement, and whose actions shall be binding upon Cheniere. 

  

	1.14	“Cheniere’s Confidential Information” has the meaning set forth in Paragraph 13.6. 

  

	1.15	“Cheniere Group” means the owners and affiliated companies of Cheniere or its lenders, including, their respective officers, directors, employees, agents, representatives,
contractors (excluding Willbros, its affiliates, Subcontractors and Vendors) and subcontractors. 

  

	1.16	“Cheniere Provided Items” means those items to be provided by Cheniere, and those responsibilities to be performed by Cheniere, as described in Paragraph 5.3.

  

	1.17	“Claim” has the meaning set forth in Paragraph 10.1.1. 

  

	1.18	“Confidential Information” has the meaning set forth in Paragraph 13.8. 

  

	1.19	“Construction Commencement Date” means the date set forth in Paragraph 6.1.2. 

  

	1.20	“Contingency Costs” means those reasonable costs actually incurred incident to the performance of Work under this Agreement and prior to Project Completion of the Project,
which are not reimbursable as a Cost of the Work, are not attributable to Willbros’ negligence, willful misconduct or breach of this Agreement, are not recoverable from Subcontractors, Vendors or insurers, and for which records required
hereunder exist and are contemporaneously prepared and maintained (“Contingency Costs”). 

  

 A-3 

	1.21	“Contingency Pool” has the meaning set forth in Attachment I of the Letter Agreement. 

  

	1.22	“Contract Amount” has the meaning set forth in Paragraph 5.4.1. 

  

	1.23	“Corrective Work” has the meaning set forth in Paragraph 12.2.2. 

  

	1.24	“Cost of the Work” has the meaning set forth in Paragraph 5.4.1. 

  

	1.25	“Defect” or “Defective” has the meaning set forth in Paragraph 12.1. 

  

	1.26	“Defect Correction Period” has the meaning set forth in Paragraph 12.2.2. 

  

	1.27	“Disclosing Party” has the meaning set forth in Paragraph 13.8. 

  

	1.28	“Dispute” has the meaning set forth in Paragraph 14.2. 

  

	1.29	“Dispute Notice” has the meaning set forth in Paragraph 14.2. 

  

	1.30	“Drawings” means drawings developed by Willbros and approved by Cheniere for the performance of the Project in accordance with Paragraph 2.7, Paragraph 2.8 and Schedule
“B” and as listed in Schedule “D”. The Drawings shall be based on the Specifications. Should there be an inconsistency between the Specifications and the Drawings, the Specifications shall prevail.

  

	1.31	“E&O Insurance” has the meaning set forth in Paragraph 11.1.7. 

  

	1.32	“Effective Date” shall be the date given in the introductory paragraph of the Signature Document. 

  

	1.33	“Exception Items” means finishing items required to complete various portions of the Work which are incomplete, Defective or otherwise not in accordance with the
Agreement, but the completion of which shall not affect, interrupt, disrupt, or interfere with the safe and orderly operation of all or a part of the Project as more fully described in Paragraph 8. 

  

	1.34	“FERC Certificate” means that certification issued by the Federal Energy Regulatory Commission (“FERC”) (i) authorizing the construction of the Project,
including any conditions governing the conduct of the construction activities for the Project, and (ii) detailing the pipeline route and required pipe class associated with the route’s population density survey. The FERC Certificate
includes related FERC filing documents CP04-38-00, CP04-38-001, CP04-39-000 and CP04-40-000 and the approved implementation plan. 

  

	1.35	 “Force Majeure” means Catastrophic Storms or floods, lightning, tornadoes, hurricanes, named tropical storms, earthquakes and other acts of God, wars,
civil disturbances, terrorist attacks, revolts, insurrections, sabotage, commercial embargoes, epidemics, fires, 

  

 A-4 

	 	 
explosions, and actions of a Governing Authority that were not requested, promoted, or caused by the affected Party, and strikes or other similar labor
actions (except as set forth in (iii) below); provided that such act or event (a) renders impossible or impracticable the affected Party’s performance of its obligations under the Agreement, (b) is beyond the reasonable control
of the affected Party and not due to its fault or negligence and (c) could not have been prevented or avoided by the affected Party through the exercise of due diligence, including the expenditure of any reasonable sum taking into account the
Guaranteed Maximum Price. For avoidance of doubt, Force Majeure shall not include any of the following: (i) a Party’s economic hardship, (ii) changes in market conditions, (iii) strikes, or other similar labor actions to the
extent caused by the act or omission of the Party claiming Force Majeure, (iv) unavailability of Subcontractors or Vendors; (v) climatic conditions (including rain, snow, wind, temperature and other weather conditions), tides, and seasons,
regardless of the magnitude, severity, duration or frequency of such climatic conditions (except those Catastrophic Storms as set forth above), or (vi) nonperformance or delay by Willbros or its Subcontractors or Vendors, unless any of the
foregoing conditions is otherwise caused by Force Majeure. 

  

	1.36	“Guaranteed Maximum Price” shall have the meaning set forth in Paragraph 3 of the Signature Document. 

  

	1.37	“Governing Authority” means any federal, state, or local department, office, instrumentality, agency, board or commission having jurisdiction over a Party or any portion
of the Work, the Work Site or the Project. 

  

	1.38	“Hazardous Substance” means any substance that under Applicable Law is considered to be hazardous or toxic or is or may be required to be remediated, including
(a) “hazardous substances” as defined in 42 U.S.C. § 9601(14), (b) “chemicals” subject to regulation under Title III of the Superfunds Amendments and Reauthorization Act (“SARA”) of 1986, (c) natural
gas liquids, liquefied natural gas or synthetic gas, (d) any petroleum, petroleum-based products or crude oil or any fraction, or (e) any other chemical, waste, material, pollutant, contaminant or any other substance, exposure to which is
now or hereafter prohibited, limited or regulated by any Governing Authority or which may be the subject of liability for damages, costs or remediation. 

  

	1.39	“Key Personnel” or “Key Persons” has the meaning set forth in Paragraph 3.1 and includes the Willbros Personnel listed in Attachment VIII.

  

	1.40	“Letter Agreement” means that letter agreement entered into between the Parties simultaneously with this Agreement dated February 01, 2006. 

 

	1.41	“Liquidated Damages” has the meaning set forth in Paragraph 21.1. 

  

	1.42	 “Major Vendor” means any Vendor (a) who has entered a subcontract or purchase order having an aggregate value in excess of One Hundred Thousand
Dollars ($100,000), or (b)

  

 A-5 

	 	 
who has entered multiple subcontracts or purchase orders with an aggregate value in excess of One Hundred Thousand Dollars ($100,000).

  

	1.43	“Mechanical Completion” or “Mechanically Complete” means that all of the following has occurred: (a) the Work is approved by Cheniere as being ready for
pre-commissioning and/or commissioning; (b) Willbros has delivered to Cheniere a set of original test and inspection certificates, including hydrostatic test reports, materials documentation, MAOP establishment records, and internal geometry
pig results; (c) Willbros has completed all construction, procurement, fabrication, assembly, erection, installation and testing, including final pipeline hydrostatic tests for the pipeline and all appropriate appurtenances to ensure that such
systems were correctly constructed, procured, fabricated, assembled, erected, installed and tested and are capable of being operated safely and reliably within the requirements contained in this Agreement; (d) Willbros has delivered to Cheniere
a Mechanical Completion Certificate for the Project in the form of Attachment III, and Cheniere has accepted such certificate by signing such certificate; (e) Willbros has dewatered and dried the pipeline to a dewpoint of negative forty
degrees Fahrenheit (-40oF); (f) Willbros has completed all Exception Items in accordance with Paragraph 8.1; and (g) Willbros has performed all other obligations required under this Agreement for Mechanical Completion.

  

	1.44	“QA/QC Plan” has the meaning set forth in Paragraph 7.1. 

  

	1.45	“Party” or “Parties” has the meaning set forth in the introductory paragraph of the Signature Document. 

  

	1.46	“Paragraph” means a paragraph in the Schedule in which it appears, unless otherwise indicated. 

  

	1.47	“Preparation and Material Receipt Commencement Date” has the meaning set forth in Paragraph 6.1.1. 

  

	1.48	“Project” means the whole of the Work to be performed by Willbros in respect of the pipeline and in accordance with this Agreement, including the construction, testing,
and commissioning of the 16-mile, 42-inch pipeline and related facilities, including an inlet monitor regulator station, a pig launcher, a 30-inch side tap, a 42-inch side tap, two- 42-inch mainline valves, and all other appropriate valves and
appurtenances, to be constructed from the Cheniere liquefied natural gas terminal to a pipeline interconnect at Johnson’s Bayou, all located entirely in Cameron Parish, Louisiana; for purposes of clarification, the Project does not include the
NGPL Meter Station and the Cameron Meadows Meter Station being developed by Cheniere. 

  

	1.49	 “Project Completion” means the date when all Work and all other obligations under this Agreement are fully and completely performed in accordance with the
terms of this Agreement, including: (a) the successful achievement of Mechanical Completion of all systems for the Project; (b) the successful achievement of Start-up of all systems for the 

  

 A-6 

	 	 
Project; (c) delivery by Willbros of all documentation required to be delivered under this Agreement, including any Work Product, Cheniere’s
Confidential Information and other documentation; (d) delivery by Willbros to Cheniere of fully executed Final Lien and Claim Waivers in the form of Attachment X – Part 2; (e) removal from the Work Site of all of Willbros
Personnel, supplies, waste, materials, rubbish and temporary facilities and restoration of the Work Site to its natural conditions in accordance with this Agreement, Applicable Law and Applicable Codes and Standards or any other requirements of any
Governing Authority; (f) delivery by Willbros to Cheniere of a Project Completion Certificate in the form of Attachment IV, which Cheniere has accepted by signing such certificate; (g) delivery by Willbros to Cheniere of evidence
acceptable to Cheniere that all Subcontractors and Vendors have been fully and finally paid, including fully executed Final Lien and Claim Waivers from all Subcontractors and Major Vendors in the form of Attachment X – Part 4;
(h) Willbros has completed all Exception Items in accordance with Paragraph 8.3; and (i) performance of all other obligations required by this Agreement for Project Completion. 

  

	1.50	“Project Schedule” means the dates for performance of the Work set forth in Schedule “F”, including the Preparation and Material Receipt Commencement
Date, the Scheduled Mechanical Completion Date and the Construction Commencement Date. 

  

	1.51	“Receiving Party” has the meaning set forth in Paragraph 13.8. 

  

	1.52	“Schedule of Values” has the meaning set forth in Paragraph 5.4.13. 

  

	1.53	“Scheduled Mechanical Completion Date” means the date set forth in Paragraph 6.1.3. 

  

	1.54	“Shared Savings” has the meaning set forth in Attachment I of the Letter Agreement. 

  

	1.55	“Signature Document” means the cover document to which all Schedules of the Agreement are attached thereto and which contains the signature page for which the Parties have
signed in order to be bound by this Agreement. 

  

	1.56	“Specifications” means those items and requirements governing the performance and standards of the Work as set forth in this Agreement, including the FERC Certificate and
those standard engineering and construction specifications developed by Willbros in accordance with Paragraph 2 and approved by Cheniere and as set forth or incorporated by reference in Schedule “D”. 

  

	1.57	“Start-up” means that all of the following has occurred: (a) the successful achievement of Mechanical Completion of all systems for the Project; (b) Cheniere has
purged the Project with either natural gas or nitrogen with assistance and support from Willbros as requested; (c) delivery by Willbros to Cheniere of a Start-up Certificate in the form of Attachment V, which Cheniere has accepted by
signing such certificate; (d) Willbros has completed all Exception Items in accordance with Paragraph 8.2; and (e) performance of all other obligations required by this Agreement for Start-up. 

  

 A-7 

	1.58	“Subcontractor” means any person or entity (other than a Vendor), of any tier, who performs any portion of the Work or otherwise furnishes labor, materials, supplies or
equipment which are a portion of the Work or in connection with the Work and who is not a direct full-time employee of Willbros. The term “Subcontractor” may be referred to throughout the Agreement as if singular in number and means a
Subcontractor or an authorized representative of Subcontractor. 

  

	1.59	“Taxes” has the meaning set forth in Paragraph 5.4.2. 

  

	1.60	“Vendor” means any person or entity, including a Major Vendor, (other than a Subcontractor), of any tier, including materialmen and equipment suppliers or renters, who,
sells or supplies materials, supplies or equipment which are to be incorporated into the Work or used in connection with the Work and who is not a direct full-time employee of Willbros. The term “Vendor” may be referred to throughout the
Agreement as if singular in number and means a Vendor or an authorized representative of a Vendor. 

  

	1.61	“Warranty” has the meaning set forth in Paragraph 12.1. 

  

	1.62	“Willbros” has the meaning set forth in the introductory paragraph of the Signature Document. 

  

	1.63	“Willbros Authorized Representative” means Mike Reifel, the person hereby authorized by Willbros to act on its behalf on all matters pertaining to the Agreement, and whose
actions shall be binding upon Willbros. 

  

	1.64	“Willbros’ Confidential Information” has the meaning set forth in Paragraph 13.7. 

  

	1.65	“Willbros Equipment” means all machinery, apparatus, equipment, materials, tools, temporary facilities and other items previously owned by Willbros or rented for the
purposes of this Project and utilized by Willbros to perform the Work but not forming a part of the Project, including also that of its Subcontractors and Vendors at whatever tier. 

  

	1.66	“Willbros’ Intellectual Property” has the meaning set forth in Paragraph 13.4. 

  

	1.67	“Willbros Management Fee” means Willbros’ lump sum fee for overhead, profit and indirect job risk which is set forth in the Schedule of Values.

  

	1.68	“Willbros Personnel” means all labor, supervisory and other personnel utilized by Willbros to perform the Work, including also those of its Subcontractors and Vendors at
whatever tier. 

  

	1.69	“Willbros Group” means the owners and affiliated companies of Willbros Engineers, Inc., and their respective officers, directors, employees, agents, representatives,
Subcontractors, and Vendors. 

  

 A-8 

	1.70	“Willbros RPI, Inc.” means the Willbros Group affiliated construction company headquartered in Houston, Texas that may be a Subcontractor to Willbros Engineers, Inc. on
this Project. 

  

	1.71	“Work” means all the work, services, duties, responsibilities and other undertakings to be performed by Willbros, its Subcontractors or its Vendors as described in this
Agreement, including that set forth in Schedule “B” and Paragraphs 2, 3 and 4. 

  

	1.72	“Work Plan” means the plan described in Paragraph 6.2 and formulated pursuant to Schedule “B” and Schedule “F” of the Agreement.

  

	1.73	“Work Product” has the meaning set forth in Paragraph 13.3. 

  

	1.74	“Work Site” means the location on which the Project shall be located which is identified in more detail in Attachment I of Schedule “B”.

 2. WILLBROS’ OBLIGATIONS 
 Subject to Paragraph 5 and in close cooperation and coordination with Cheniere, and subject to the terms and conditions of the Agreement, Willbros shall perform the Work in accordance with good engineering and
construction practices, Applicable Law, Applicable Codes and Standards, the Specifications and all other provisions of this Agreement. Willbros accepts the relationship of trust and confidence established by this Agreement and covenants with
Cheniere to exercise its skill and judgment in furthering the interests of Cheniere. Without limiting the generality of the foregoing or the requirements of any other provisions of this Agreement, Willbros shall: 
  

	2.1	Engineering, Procurement and Construction Management: Perform the Project management, engineering, procurement, construction and construction management for the Project as
described in this Agreement, including in detail at Schedule “B” and the Specifications set forth in Schedule “D”; 

  

	2.2	Manpower and Equipment: Provide Willbros Equipment and Willbros Personnel, including Subcontractors and Vendors, as set forth in more detail in Paragraph 3;

  

	2.3	Compliance: Perform the Work in compliance with the requirements of and provide assistance and documentation to Cheniere as reasonably requested by Cheniere in connection
with those approvals, permits, licenses, and/or other authorizations obtained by Cheniere in accordance with Paragraph 5.1; 

  

	2.4	 Health, Safety and Environmental Performance: Perform the Work in a safe, physically secure and environmentally sound manner and otherwise in compliance with
Cheniere’s health, safety and environmental policies, which are attached hereto as Attachment IX. Cheniere’s provision of such health, safety and environmental policies shall not in any 

  

 A-9 

	 	 
way relieve Willbros of its responsibility regarding safety, health or the environment, and Cheniere, in providing such policies, assumes no liability for
the policies; 

  

	2.5	Authorized Representative: Appoint one (1) or more Willbros Authorized Representative for the duration of the Work; 

  

	2.6	Timeliness and Manner of Performance: Perform all Work in a timely, complete and workmanlike manner in accordance with this Agreement; 

  

	2.7	Drawings and Specifications: Prepare, for Cheniere’s review and approval in accordance with Paragraph 2.8, all necessary Drawings and Specifications for the Project in
accordance with the Applicable Codes and Standards, Applicable Law, Schedule “B”, Schedule “D” and all other requirements within this Agreement; and 

  

	2.8	Review and Approval of Drawings and Specifications: 

  

	 	2.8.1 	Over the Shoulder Review: During the development of the Drawings and Specifications, provide Cheniere with the opportunity to perform “over-the-shoulder” reviews of
the design and engineering in progress. Such reviews may be conducted at Willbros’ office located in Tulsa, Oklahoma, at any of its Subcontractors’ offices or remotely by electronic internet access. The reviews may be of progress prints,
computer images, draft documents, working calculations, draft specifications or reports, Drawings, Specifications or other design documents determined by Cheniere. 

  

	 	2.8.2 	Submission by Willbros: Submit copies of the Drawings and Specifications to Cheniere for formal review, comment, disapproval and approval in accordance with this Paragraph 2.

  

	 	2.8.3 	Review Periods and Cheniere’s Approval: Allow Cheniere up to fifteen (15) days from Cheniere’s receipt of the Drawings and Specifications submitted in
accordance with Paragraph 2.8.2 to issue written comments, proposed changes and/or written approvals or disapprovals of the submission of such Drawings and Specifications to Cheniere. 

  

	 	(i)	If Cheniere does not issue any comments, proposed changes or written approvals or disapprovals within such time period, Willbros may proceed with the development of such Drawings
and Specifications and any construction or procurement relating thereto, but Cheniere’s lack of comments, approval or disapproval shall in no event constitute an approval of the matters received by Cheniere. 

  

	 	(ii)	 In the event that Cheniere disapproves the Drawings or Specifications, Cheniere shall provide Willbros with a written statement of the reasons for such rejection
within the time period required for Cheniere’s response for 

  

 A-10 

	 	 
disapproval of the Drawings or Specifications. Willbros shall provide Cheniere with revised and corrected Drawings or Specifications as soon as possible
thereafter and Cheniere’s rights with respect to the issuing of comments, proposed changes or approvals or disapprovals of such revised and corrected Drawings or Specifications are governed by the procedures specified in this Paragraph 2.8.3;
provided that Willbros shall not be entitled to any extensions of time to the Project Schedule, the Preparation and Material Receipt Commencement Date, the Construction Commencement Date, the Scheduled Mechanical Completion Date, or an adjustment to
the Guaranteed Maximum Price. 

  

	 	(iii)	Upon Cheniere’s written approval of the Drawings and Specifications, such Drawings and Specifications shall be the Drawings and Specifications that Willbros shall use to
construct the Work; provided that Cheniere’s review or approval of any Drawings or Specifications shall not in any way be deemed to limit or in any way alter Willbros’ responsibility to perform and complete the Work in strict accordance
with the requirements of this Agreement, and in the event that there is a discrepancy, difference or ambiguity between the terms of this Agreement and any Drawings or Specifications, the Agreement shall control. Due to the limited time under this
Agreement for Cheniere’s review of the Drawings and Specifications, Willbros’ or its Subcontractors’ or Vendors’ expertise in the Work and Cheniere’s reliance on Willbros to prepare accurate and complete Drawings and
Specifications, Willbros recognizes and agrees that Cheniere is not required or expected to make detailed reviews of the Drawings and Specifications, but instead Cheniere’s review of the Drawings or Specifications may be of only a general,
cursory nature. Accordingly, any reviews or approvals given by Cheniere under this Agreement with respect to any Drawings or Specifications shall not in any way be, or deemed to be, an approval of any Work or Drawings or Specifications not meeting
the requirements of this Agreement, as Willbros has the sole responsibility for performing the Work in accordance with the requirements of this Agreement. 

  

	2.9	 Audit Rights: During the term of this Agreement and for a period of three (3) years after the earlier of Project Completion or termination of this
Agreement, retain full and detailed books, construction logs, Drawings, Specifications, Change Orders, records, daily reports, accounts, payroll records, receipts, statements, electronic files (including schedules, e-mails and CAD), correspondence,
subcontracts and other documents of Willbros, its affiliated companies or their respective Subcontractors and Vendors, which in any way: (a) pertain to the Agreement, including any such documents related to the Work; or (b) relate to
costs, compensation for changes in the Work, or claims of any type by Willbros or its Subcontractors or Vendors (“Books and Records”). Upon five (5) days’ written notice, Cheniere or any of its representatives shall have the
right to audit such Books and Records during such three (3) year period, provided, however, such parties shall not have the right to audit or have audited Books and Records in connection 

  

 A-11 

	 	 
with the internal composition of any compensation that is fixed in amount hereunder such as the composition of unit rates or hourly rates. When requested by
Cheniere, Willbros shall provide the auditors with reasonable access to all such Books and Records, and Willbros Personnel shall cooperate with the auditors to effectuate any audit hereunder. The auditors shall have the right to copy all such Books
and Records. Willbros shall include audit provisions identical to this Paragraph 2.9 in all subcontracts and purchase orders with Subcontractors and Vendors. Willbros shall maintain all Books and Records in accordance with generally accepted
accounting principles applicable in the United States. Willbros will not charge for any costs incurred by it in assisting Cheniere with audits performed pursuant to this Paragraph 2.9. Willbros obligations under this Paragraph 2.9 shall survive the
termination of this Agreement. 

 3. WILLBROS PERSONNEL AND EQUIPMENT 
  

	3.1	Key Personnel: Willbros Personnel shall be provided in sufficient numbers, and shall be competent and fully qualified to execute the Work. Willbros shall submit to
Cheniere’s Authorized Representative an updated organization chart of key Project personnel from Willbros’ or its Subcontractors’ or Vendors’ organization (“Key Personnel” or “Key Persons”) who shall be
assigned to the Work, such organization chart to be in the form of and attached as Attachment VIII. Key Personnel shall, unless otherwise expressly stated in such organization chart, be devoted full-time to the Work for the entire duration of
the Project, and Key Personnel shall not be removed or reassigned without Cheniere’s prior written approval. Cheniere shall have the right, but not the obligation, at any time to request that Willbros replace any Key Person with another
employee acceptable to Cheniere. In such event, Willbros shall replace such Key Person without additional expense to Cheniere. 

  

	3.2	Willbros Equipment: Willbros Equipment shall be suitable for the performance of the Work, in good repair and otherwise comply with the terms of this Agreement.
Notwithstanding anything to the contrary contained in this Agreement, Willbros shall be responsible for repair, damage to or destruction or loss of, from any cause whatsoever, all Willbros Equipment. Willbros shall require that all insurance
policies (including policies of Willbros and all Subcontractors and Vendors) in any way relating to such Willbros Equipment include clauses stating that each underwriter will waive all rights of recovery, under subrogation or otherwise, against the
Cheniere Group. 

  

	3.3	 Subcontractors and Vendors: Cheniere acknowledges and agrees that Willbros intends to have portions of the Work accomplished by Subcontractors or Vendors
pursuant to written subcontracts or purchase orders between Willbros and such Subcontractors and Vendors, and that such Subcontractors and Vendors may have certain portions of the Work performed by lower tier subcontractors or vendors. All
Subcontractors and Vendors shall be reputable, qualified firms with an established record of successful performance in their respective trades performing identical or substantially similar work. All contracts with Subcontractors and Vendors shall be
consistent with the terms or provisions of this Agreement. No Subcontractor or Vendor is intended to be or shall be 

  

 A-12 

	 	 
deemed a third party beneficiary of this Agreement. Willbros shall be fully responsible to Cheniere for the acts or omissions of Subcontractors and Vendors
and of persons directly or indirectly employed by either of them, as Willbros is for the acts or omissions of persons directly employed by Willbros. The Work of any Subcontractor or Vendor shall be subject to inspection by Cheniere to the same
extent as the Work of Willbros. Nothing contained herein shall (i) create any contractual relationship between any Subcontractor or Vendor and Cheniere, or (ii) obligate Cheniere to pay or cause the payment of any amounts to any
Subcontractor or Vendor. Willbros shall, within thirty (30) days prior to the selection of any Subcontractor or Vendor, notify Cheniere in writing of the selection of such Subcontractor or Vendor and inform Cheniere generally what portion of
the Work such Subcontractor or Vendor is performing. 

  

	3.4	Bidding of Subcontracts and Purchase Orders: As part of Willbros’ performance of the Work on an “open book basis”, Willbros shall provide all necessary
services related to the bidding of subcontracts and purchase orders for the construction and procurement components of the Work, including the following: (a) preparing lists of prospective bidders for review by Cheniere; (b) preparing
appropriate bid documents, including proposed forms of subcontract and purchase orders; (c) establishing bid schedules; (d) advertising for bids and developing bidder interest; (e) furnishing information concerning the Project to
prospective bidders; (f) conducting pre-bid conferences; (g) receiving bids, as described below, and analyzing bids and making recommendations to Cheniere regarding bid awards; (h) investigating the acceptability and responsibility of
lower-tiered Subcontractors and Vendors proposed by any Subcontractor or Vendor and advising Cheniere of such evaluations; (i) negotiating with Subcontractors and Vendors concerning any matter related to the Project; and (j) providing such
other services required by Cheniere with respect to the bidding process. Willbros shall require bidders to submit their sealed bids directly to Willbros, and Willbros shall forward copies of such bids to Cheniere. Willbros shall require bidders for
the construction component of the Work to submit their sealed bids directly to Cheniere and copies of such bids to Willbros. The receipt of the proposed bidders list by Cheniere shall not require Cheniere to investigate the qualifications of
prospective bidders, nor shall it waive the right of Cheniere to later object to or reject any proposed Subcontractors or Vendors. 

  

	3.5	Cheniere Approval of Subcontractors and Vendors: 

  

	 	3.5.1 	Approved Subcontractors and Vendors List: Attachment VII sets forth a list of Subcontractors and Vendors that Willbros and Cheniere have agreed are approved
Subcontractors and Vendors for the performance of that stated portion of the Work specified in Attachment VII. Approval by Cheniere of any Subcontractors or Vendors does not relieve Willbros of any responsibilities under this Agreement.
Unless Cheniere otherwise approves, each prospective bidder list shall contain at least three (3) Subcontractors or Vendors from the Approved Subcontractors and Vendors List in Attachment VII. 

  

 A-13 

	 	3.5.2 	Additional Proposed Subcontractors and Vendors: In the event that Willbros is considering the selection of a Subcontractor or Vendor not listed on Attachment VII,
Willbros shall (i) notify Cheniere of its proposed Subcontractor or Vendor as soon as possible during the selection process, including clearly identifying such proposed Subcontractor or Vendor on the list of prospective bidders provided in
accordance with Paragraph 3.4, and furnish to Cheniere all information reasonably requested by Cheniere with respect to Willbros’ selection criteria, and (ii) notify Cheniere no less than seven (7) business days prior to the execution
of a subcontract or purchase order with a Subcontractor or Vendor not listed on Attachment VII. Cheniere shall have the discretion, not to be unreasonably exercised, to reject any proposed Subcontractor or Vendor not listed on Attachment
VII at any time. Willbros shall not enter into any subcontract or purchase order with a proposed Subcontractor or Vendor that is rejected by Cheniere in accordance with the preceding sentence. Cheniere shall undertake in good faith to review the
information provided by Willbros with respect to such proposed Subcontractor or Vendor expeditiously and shall notify Willbros of its decision to accept or reject a proposed Subcontractor or Vendor as soon as practicable after such decision is made.
Failure of Cheniere to accept a proposed Subcontractor or Vendor within seven (7) business days shall be deemed to be a rejection of such Subcontractor or Vendor. 

 4. WORK SITE RESPONSIBILITIES 
  

	4.1	Land Acquisition Plan: Willbros shall provide reasonable assistance to Cheniere, as requested by Cheniere in writing, in finalizing Cheniere’s land acquisition plan as
necessary to permit land activities for the Project to proceed in accordance with the FERC Certificate and in accordance with Paragraph 5.2. Such plan may include required rights of way, access roads, materials and equipment storage facilities,
office sites, vehicle parking areas, temporary electrical supply locations and trash collection areas, including proposed locations for each. 

  

	4.2	Provision of Facilities: Willbros shall provide warehousing, offices, storage and related utilities in accordance with the terms of this Agreement and the FERC Certificate
for Willbros Equipment and such other materials and equipment to be incorporated into the Work. 

  

	4.3	Maintenance of Work Sites: Willbros shall, to Cheniere’s satisfaction, at all times keep the Work Site free from all waste materials or rubbish caused by the activities
of Willbros or any of its Subcontractors or Vendors. Without limitation of the foregoing or limiting Willbros’ obligations, Willbros shall clean up all such waste materials or rubbish at Cheniere’s request with reasonable notice.

  

	4.4	 Compliance with Real Property Interests and Other Work Site Restrictions: Willbros shall, in the performance of the Work, comply, and cause all
Subcontractors and Vendors to comply, with any agreement governing any easement, lease, right-of-way or other 

  

 A-14 

	 	 
property interests that affect or govern the Work Site or any other real property used for the purposes of completing the Work, including any line list,
insurance or indemnification restrictions or obligations therein, to the extent such easement, lease, right-of-way or other property interests relate to the performance of the Work (but only to the extent that such indemnification restrictions and
obligations are consistent with Willbros indemnification obligations agreed to herein). In addition, Willbros shall comply with any one-call requirements imposed by Applicable Law (including local law) and coordinate with owners or operators of all
third-party utilities, including those crossed by the Project or otherwise situated within the Work Site or affected by the Work. Cheniere shall provide Willbros with copies of all relevant portions of the agreements governing such easement, lease,
right-of-way, and other property interests to the extent that such agreements impose restrictions or obligations on Willbros pursuant to this Paragraph 4.4. To the extent that such agreements require Willbros to procure insurance in addition to or
in amounts in excess of that insurance required by this Agreement, the Willbros shall be entitled a Change Order increasing the Guaranteed Maximum Price to cover the cost of such additional insurance. 

  

	4.5	Coordination of Work: Willbros acknowledges that Cheniere and other consultants and contractors may be working at the Work Site during the performance of this Agreement and
the Work or use of certain facilities may be interfered with as a result of such concurrent activities, and Willbros agrees to coordinate the performance of the Work with Cheniere and such other consultants and contractors performing work at the
Work Site so as not to materially interfere with Cheniere or its other consultants or subcontractors performing work at the Work Site. 

 5. CHENIERE’S OBLIGATIONS 
 In close cooperation and coordination with Willbros, and subject to the terms and conditions of the
Agreement, Cheniere shall: 
  

	5.1	Licenses and Permits: Provide, or cause to be provided, all approvals, permits, licenses (other than Willbros’ or its Subcontractors’ or Vendors’ operating and
professional licenses, including road bonding) and/or other authorizations necessary for the Project from any Governing Authority, including the FERC Certificate and all environmental agencies. 

  

	5.2	Work Site Access: Secure legal and reasonable access to the Work Site, in accordance with the FERC Certificate, as necessary to permit Willbros to commence Work in accordance
with this Agreement by obtaining the rights of way, pipe yards, ware yards, and all other land rights or property interests necessary for the Work, all in accordance with Cheniere’s land acquisition plan. 

  

	5.3	 Cheniere Provided Items: Cheniere shall provide: (i) hydrostatic test water; (ii) natural gas or nitrogen and personnel to determine the
achievement of Start-up in accordance with Paragraphs 1.57 and 8.2; and (iii) environmental inspection services during 

  

 A-15 

	 	 
construction Work. In addition, Cheniere shall provide to Willbros the following preliminary drawings which shall be updated by Willbros in accordance with
this Agreement: (y) preliminary drawings submitted to FERC, indicated by drawing numbers CH-5763-D-1103 (Sheets 1 to 6), Rev. 0 and titled “Proposed 42-inch Natural Gas Pipeline, Sabine Pass Pipeline Project, FERC Alignment Sheet,”
and (z) preliminary alignment drawings, indicated by drawing numbers CH-5763D-1101 to 1115, Rev. 1 and titled “Cheniere, Sabine to Johnson’s Bayou, Cameron Parish, Louisiana.” 

  

	5.4	Payment: Remunerate Willbros as required by the Agreement. 

  

	 	5.4.1 	Contract Amount: Subject to additions and deductions by Change Order, Cheniere shall pay Willbros for performance of the Work to be performed by Willbros for the Project as
described in this Agreement and Schedule “B”, the “Contract Amount” consisting of (i) the Cost of the Work, (ii) the Willbros Management Fee, (iii) Contingency Costs, and (iv) Louisiana sales and use
taxes applicable to permanent materials and equipment to be incorporated into the Project. The “Cost of the Work” shall mean those costs necessarily incurred by Willbros in good faith in the proper performance of the Work.

  

	 	5.4.2 	 Taxes: The Guaranteed Maximum Price includes any and all taxes, assessments, levies, duties, fees, charges and withholding of any kind or nature whatsoever
and howsoever described, including value-added, sales and use taxes (except as indicated herein), gross receipts, license, payroll, environmental, profits, premium, franchise, property, excise, capital stock, import, stamp, transfer, employment,
occupation, generation, privilege, utility, regulatory, energy, consumption, lease, filing, recording and activities taxes, levies, duties, fees charges, imposts and withholding, together with any and all penalties, interests and additions thereto
in any way related to the Work (collectively, “Taxes”), but not including Louisiana sales and use taxes applicable to permanent materials and equipment to be incorporated into the Project, the cost of which is not subject to the Guaranteed
Maximum Price. With each invoice that requests reimbursement for Louisiana sales and use taxes applicable to permanent materials and equipment to be incorporated into the Project, Willbros shall separately list in the invoice such Louisiana sales
and use taxes. Subject to the other provisions of this Agreement, Cheniere shall remit to Willbros the payment of such Louisiana sales and use taxes within the time allowed for payment of invoices under this Agreement. Willbros shall be responsible
for paying to the applicable Governing Authority all Taxes and Louisiana sales and use taxes applicable to permanent materials and equipment to be incorporated into the Project owed under Applicable Law with respect to the Work. IF AND TO THE EXTENT
CHENIERE HAS PAID TO WILLBROS THE APPLICABLE TAXES AND LOUISIANA SALES AND USE TAXES APPLICABLE TO PERMANENT MATERIALS AND EQUIPMENT TO BE INCORPORATED INTO THE PROJECT REQUIRED UNDER THIS PARAGRAPH, WILLBROS SHALL INDEMNIFY, DEFEND AND HOLD
HARMLESS THE CHENIERE GROUP FROM AND AGAINST ANY CLAIMS 

  

 A-16 

	 	 
BY ANY GOVERNING AUTHORITY FOR THE NON-PAYMENT OF SUCH TAXES AND SUCH LOUISIANA SALES AND USE TAXES. 

  

	 	5.4.3 	Invoicing: Willbros shall submit invoices to Cheniere as follows: 

  

	 	(i)	twice per month for Project management, engineering and drafting, procurement services, and construction management services performed during the previous invoicing period. Charges
shall be accumulated and invoiced on a rate reimbursable basis reflecting man-hours expended as described in Paragraph 1.2 of Attachment I to the Letter Agreement; 

  

	 	(ii)	for permanent materials as set forth in Paragraph 1.3 of Attachment I to the Letter Agreement; 

  

	 	(iii)	for the construction component of the Work as set forth in Paragraph 1.4 of Attachment I to the Letter Agreement; 

  

	 	(iv)	for the Willbros Management Fee properly allocable to the completed Work. The Willbros Management Fee allocable to the completed Work shall be determined by multiplying the
percentage completion of the Work by the total amount of the Willbros Management Fee payable to Willbros for the Project; and 

  

	 	(v)	for Willbros’ portion of any Shared Savings upon Project Completion. 

  

	 	5.4.4 	Invoice Format: Invoices shall be complete with sufficient detail and itemized to facilitate Cheniere’s confirmation and approval. Willbros’ invoices shall be in a
format and supported by such documentation as required by Cheniere. Without limitation of the foregoing, Willbros shall, with each invoice, submit payrolls, petty cash accounts, receipted invoices or invoices with check vouchers attached, and any
other evidence required by Cheniere to demonstrate that cash disbursements already made by Willbros on account of the Cost of the Work equal or exceed (i) progress payments already received by Willbros; less (ii) that portion of those
payments attributable to the Willbros Management Fee; plus (iii) payrolls for the period covered by the present invoice. Invoices shall show the percentage of completion of each portion of the Work as of the end of the period covered by the
invoice. The percentage of completion shall be the lesser of: (1) the percentage of that portion of the Work which has actually been completed; or (2) the percentage obtained by dividing (a) the expense that has actually been incurred
by Willbros on account of that portion of the Work for which Willbros has made or intends to make actual payment prior to the next invoice by (b) the share of the Guaranteed Maximum Price allocated to that portion of the Work in the Schedule of
Values. 

  

 A-17 

	 	5.4.5 	Payment Terms: Cheniere shall pay Willbros all undisputed amounts due hereunder within fifteen (15) days after receipt of a complete and accurate invoice for Work that
is satisfactorily completed during that period. 

  

	 	5.4.6 	Lien and Claim Waivers: Each progress invoice shall be accompanied by a fully executed Willbros’ Interim Lien and Claim Waiver in the form of Attachment X – Part
1, a fully executed Interim Lien and Claim Waiver in the form of Attachment X – Part 3 for each Subcontractor and Major Vendor, and such other evidence satisfactory to Cheniere to ensure that all amounts owed in connection with
performance of this Agreement, including amounts owed to all Subcontractors and Vendors, have been paid. Waivers of liens and claims, however, will not be required from Subcontractors or Vendors until they have performed Work or furnished materials
or equipment, and Willbros, Subcontractors and Major Vendors will be required to submit waivers of liens and claims only if they have performed Work or furnished materials or equipment not covered by a previous waiver. Receipt of all Interim Lien
and Claim Waivers under this Paragraph 5.4.6 or all Final Lien and Claim Waivers required to meet the requirements of Paragraph 1.49, as applicable, is a condition precedent to payment of any amounts under an invoice. 

  

	 	5.4.7 	Final Invoice: Prior to submission of a final invoice, Willbros shall perform an audit to determine the total Cost of the Work for the Project. Such audit shall also take
into consideration Contingency Costs expended and the Willbros Management Fee in order to calculate the Actual Contract Amount in accordance with Paragraph 2.2 of Attachment I to the Letter Agreement. Willbros shall provide a copy of such
audit report to Cheniere upon submission of Willbros’ final invoice. Cheniere’s accountants will review and report in writing on Willbros final audit within thirty (30) days after delivery thereof by Willbros. If Cheniere’s
accountants report the Cost of the Work and Contingency Costs as substantiated by Willbros final audit to be less than claimed by Willbros, and Willbros disagrees with Cheniere’s accountants reporting of the Cost of the Work and Contingency
Costs, Willbros has the right, within seven (7) days of its receipt of the Cheniere’s accountants’ report, to submit the Dispute for resolution in accordance with Paragraph 14. If Willbros fails to submit the Dispute within such seven
(7) day period, Willbros shall be deemed to have agreed with Cheniere’s accountants report on the Cost of the Work and Contingency Costs. Final payment shall not be made until resolution of a Dispute under this Paragraph 5.4.7.

  

	 	5.4.8 	 Unperformed Obligations: Project Completion and payments made hereunder shall not in any way release Willbros or any surety of Willbros or its Subcontractors
from any unperformed obligations of the Agreement, including Warranties, compliance with the Agreement, liabilities for which insurance is required or any other responsibility of Willbros, including the payment of any and 

  

 A-18 

	 	 
all fines and penalties assessed as a result of Willbros’ failure to comply with Applicable Law or Applicable Codes and Standards.

  

	 	5.4.9	  Withholding: In addition to retainage and amounts withheld that are in dispute, Cheniere may, in addition to any other rights at law, in equity or under this
Agreement, withhold amounts otherwise due by Cheniere to Willbros without payment of interest on account of: (a) Defective Work not remedied by Willbros in accordance with Paragraph 12; (b) the filing of claims or liens or evidence
indicating the probable filing of claims or liens against Cheniere, the Project or the Work; (c) failure of Willbros to pay amounts when due for labor, services or material used by Willbros in performing the Work or amounts due to
Subcontractors or Vendors as required in their respective subcontracts and purchase orders; (d) the assessment of any fines or penalties against Cheniere as a result of Willbros’ failure to comply with Applicable Law or Applicable Codes
and Standards; or (e) any other circumstance permitted under this Agreement. If and when the cause, or causes, for withholding any such payment shall be remedied or removed and satisfactory evidence of such remedy or removal has been presented
to Cheniere, the payments withheld shall be made to Willbros in the next invoice and if the final invoice has been paid, within thirty (30) days of such remedy or removal. 

  

	 	5.4.10 	Payment Account Number: Payments to Willbros under this Agreement shall be made by wire transfer to: 

 Southwest Bank of Texas 
 Houston, Texas

 ABA#: 113-011-258 
 Beneficiary: Willbros USA, Inc. 
 Account Number: 127736 
  

	 	5.4.11 	Address for Invoicing: Willbros shall submit invoices for payment to: 

 Cheniere Sabine Pass Pipeline 
 717 Texas Avenue, Suite 3100 
 Houston, Texas 77002 
 Telephone:
        (713) 659-1361 
 E Mail
              abartz@cheniere.com 
 Facsimile:         (713) 659-5459 
 Attention:
        Mr. Allan Bartz 
 Or such other addressee and location as Cheniere may direct in
writing. 
  

	 	5.4.12 	 Payment of Shared Savings: Willbros shall be paid its share of the Shared Savings within thirty (30) days of settlement and verification thereof by the

  

 A-19 

	 	 
Parties following Cheniere’s receipt of a final invoice and accounting report from Willbros in accordance with Paragraphs 5.4.4 and 5.4.7.

  

	 	5.4.13 	Schedule of Values: Attachment IV of the Letter Agreement sets forth the schedule of values allocating the entire Guaranteed Maximum Price among the various portions
of the Work as of the Effective Date of the Agreement (“Schedule of Values”) to be used as a basis for reviewing the invoices. Willbros shall periodically, upon award of various components of the Work to Subcontractors and Vendors, submit
to Cheniere for Cheniere’s written approval an updated Schedule of Values allocating the entire Guaranteed Maximum Price among the various portions of the Work, except that the Willbros Management Fee shall be shown as a separate line item. The
updated Schedule of Values shall be prepared in such form and supported by such data to substantiate its accuracy as Cheniere may require. Each Cheniere-approved, updated Schedule of Values shall be incorporated into this Agreement by Change Order.

 6. WORK PLAN AND REPORTS 
  

	6.1	Time for Performance: Willbros shall commence performance of the Work upon the Effective Date and shall perform the Work in accordance with the Project Schedule set forth in
this Paragraph 6 and in Schedule “F”. TIME IS OF THE ESSENCE with respect to Willbros’ performance of the Work. Willbros may not commence a portion of the Work prior to the relevant commencement date, if any, listed below:

  

	 	6.1.1 	Willbros shall commence Work related to ware yard preparation and material receipt at the Work Site no earlier than January 01, 2007 (“Preparation and Material Receipt
Commencement Date”). The Preparation and Material Receipt Commencement Date shall only be adjusted by Change Order as provided under this Agreement. 

  

	 	6.1.2 	Willbros shall commence Work related to the construction of the Project at the Work Site no earlier than April 01, 2007 (“Construction Commencement Date”). The
Construction Commencement Date shall only be adjusted by Change Order as provided under this Agreement. 

  

	 	6.1.3 	Willbros shall achieve Mechanical Completion of the Project no later than September 30, 2007 (“Scheduled Mechanical Completion Date”) based on an April 1, 2007,
release for construction. The Scheduled Mechanical Completion Date shall only be adjusted by Change Order as provided under this Agreement. 

  

	6.2	 Work Plan: On or before February 28, 2006, Willbros shall prepare and submit to Cheniere’s Authorized Representative for review and written
approval, a detailed critical path method schedule in a format approved by Cheniere (“Work Plan”). The Work Plan shall be based on and consistent with the Project Schedule, including the Preparation and Material Receipt Commencement Date,
the Construction Commencement Date and the 

  

 A-20 

	 	 
Scheduled Mechanical Completion Date, shall show the method and order in which Willbros shall perform the Work, its subcontracting plan, and any other
information that Cheniere may consider useful. The Work Plan shall represent Willbros’ best judgment as to how it shall achieve Mechanical Completion by the Scheduled Mechanical Completion Date, and shall be a detailed graphic representation of
all significant aspects of the Work showing Willbros’ plans for performance of the Work. Without limitation of the foregoing, the Work Plan shall include separate activities for each portion of the Work, show the duration, early/late start
dates, early/late finish dates and available float for each activity, show activity number, activity description and responsible Subcontractor or Vendor, and show an uninterrupted critical path from commencement of the Work through Project
Completion. 

  

	6.3	Updated Work Plan: The Work Plan shall be used as the basis for progress reporting, schedule control and schedule forecasting. As reasonably requested by Cheniere, Willbros
shall revise the Work Plan to include the effect of Change Orders and Amendments and to reflect actual Work in progress as agreed with Cheniere, provided, however, Willbros may not modify the Preparation and Material Receipt Commencement Date, the
Construction Commencement Date or the Scheduled Mechanical Completion Date without a Change Order being executed in accordance with this Agreement. Each updated Work Plan shall provide the same details and form as required of the Work Plan. Willbros
shall prepare schedule and cash flow forecasts on a monthly basis or as requested by Cheniere that reasonably predict the date for Mechanical Completion of the Project. Willbros shall notify Cheniere of any anticipated or actual slippage in the
performance of the Work as compared to the Work Plan. Willbros shall provide to Cheniere weekly reports, monthly summaries of such reports, and upon request, all other relevant information concerning any circumstance or condition affecting the Work.

  

	6.4	Progress Meetings: Work progress meetings between Authorized Representatives shall be held monthly between Cheniere and Willbros. 

  

	6.5	 Recovery: If Willbros is responsible for any delays in the time and/or sequence of the performance of the Work that is on the critical path of the Work Plan,
Willbros shall on its own initiative or at Cheniere’s written directive, employ such additional forces, obtain such additional equipment, employ such additional supervision, pay such additional overtime wages, and use such priority freight as
may be required to bring the Work back on schedule. If Willbros’ progress is more than fourteen (14) days behind the critical path of the Work Plan, Cheniere may, without prejudice to any other remedies available to it under this
Agreement, also require in writing that Willbros submit, within two (2) days of Cheniere’s written notice and for Cheniere’s approval, a recovery plan to Cheniere detailing Willbros’ proposal for bringing the Work back on
schedule and that the sequence of the performance of the Work be changed. In no event shall such costs to bring the Work back on schedule cause the Guaranteed Maximum Price to be exceeded. This Paragraph 6.5 shall not be construed to require that
Cheniere give Willbros a written notice to perform any of the acts listed herein, and the Parties agree that Cheniere’s 

  

 A-21 

	 	 
failure to give such written notice to Willbros shall not in any way relieve Willbros of its obligation to perform the Work within the times set forth in the
Project Schedule. 

  

	6.6	Acceleration: Even if the Work is otherwise in compliance with the Work Plan, Cheniere may, at any time, direct Willbros to accelerate the Work by, among other things,
establishing additional shifts, paying or authorizing overtime or providing additional equipment. In the event of this directive, Cheniere’s sole liability to Willbros shall be to pay Willbros for any documented costs clearly and solely
attributable to such acceleration. Such costs may include any shift differential, premium, or overtime payments to workers or field supervisors and other employees of Willbros dedicated to the Work on a full-time basis actually incurred over and
above Willbros’ normal rates, overtime charges for equipment, amounts to account for lost efficiency of workers and other costs agreed upon by Cheniere and Willbros in writing. Any adjustment to the Guaranteed Maximum Price resulting from
Cheniere’s directive to accelerate the Work shall be implemented by Change Order. 

 7. INSPECTION AND TESTING

  

	7.1	QA/QC Plan: On or before March 31, 2006, Willbros shall submit to Cheniere’s Authorized Representative, for review and written approval thereof, a quality assurance
and quality control plan for materials procurement and for construction (“QA/QC Plan”). Cheniere’s review and approval of the QA/QC Plan shall in no way relieve Willbros of its responsibility for performing the Work in compliance with
this Agreement. 

  

	7.2	Willbros’ Inspection and Testing of Work: Willbros shall inspect and test the overall and component parts of the Work, including that of its Subcontractors or Vendors,
to ensure conformity of such Work with Applicable Codes and Standards, and all other obligations within this Agreement. 

  

	7.3	Cheniere Inspection of Work: All Work shall be subject to inspection by Cheniere or its designee at all times and at Cheniere’s own expense, to determine whether the
Work conforms to the requirements of this Agreement. Willbros shall furnish Cheniere with access to all locations where Work is in progress, including locations not on the Work Site such as locations from where equipment and material are being
obtained, including pipe fabrication and coating and factory testing of mainline valves. 

  

	7.4	 Correction of Work Prior to Start-up: If, in the judgment of Cheniere, any Work is Defective or any Work is determined to be Defective as a result of the
testing and inspections performed pursuant to Paragraph 7.2, then Willbros shall, at its own expense, promptly correct such Defective Work, whether by repair, replacement or otherwise. Subject to Willbros’ right to pursue a Dispute under
Paragraph 14, the decision of Cheniere shall be conclusive as to whether the Work is conforming or Defective, and Willbros shall comply with the instructions of Cheniere in all such matters while pursuing any such Dispute. If it is later determined
that the Work was not Defective, then Cheniere shall reimburse Willbros for all costs incurred in connection with such repair or 

  

 A-22 

	 	 
replacement and a Change Order shall be issued for such amount and shall address any impact the repair or replacement may have had on the Project Schedule.
If Willbros fails, after a reasonable period of time not to exceed five (5) days, to repair or replace any Defective Work, or to commence to repair or replace any Defective Work and thereafter continue to proceed diligently to complete the
same, then Cheniere may repair or replace such Defective Work and the expense thereof shall be paid by Willbros. 

  

	7.5	Notice to Cheniere and Cost of Disassembling: Willbros shall advise Cheniere’s Authorized Representative of tests to be witnessed sufficiently in advance to enable him
or his designee to attend and witness such test at Cheniere’s expense. Willbros shall likewise advise Cheniere’s Authorized Representative in advance of any critical component of the Work to be closed or covered. If such action is taken by
Willbros before an opportunity to inspect or witness has been provided to Cheniere, it must, if required by Cheniere, be opened or uncovered for inspection or witnessing and recovered at Willbros’ expense. The cost of disassembling, dismantling
or making safe finished Work for the purpose of inspection, other than as set forth above, and reassembling such portions (and any delay associated therewith) shall be borne by Cheniere if such Work is found to conform with the requirements of this
Agreement and by Willbros if such Work is found to be Defective. 

  

	7.6	No Obligation to Inspect: Cheniere’s right to conduct inspections under this Paragraph 7 shall not obligate Cheniere to do so. Neither the exercise of Cheniere of any
such right, nor any failure on the part of Cheniere to discover or reject Defective Work shall be construed to imply an acceptance of such Defective Work or a waiver of such Defect. 

 8. COMPLETION AND START-UP 
  

	8.1	Mechanical Completion: Willbros shall comply with all requirements for Mechanical Completion, including as set forth in the definition of the term Mechanical Completion and
elsewhere in this Agreement. When Willbros believes the Work is Mechanically Complete, Willbros shall certify to Cheniere in writing in the form of the Mechanical Completion Certificate attached hereto as Attachment III that all of the
requirements for Mechanical Completion of the Work have occurred, including all documentation required to establish that the requirements for Mechanical Completion have been met. Within seven (7) days after receipt of such notice Cheniere shall
inspect the Work and either accept the Work as being Mechanically Complete (which acceptance shall be evidenced by Cheniere’s signature on such Mechanical Completion Certificate), or specify the Exception Items which must be completed to
achieve Mechanical Completion in a written notice to Willbros. Upon completion or correction of such Exception Items, Willbros shall so advise Cheniere. Within seven (7) days after receipt of such notice, Cheniere shall either accept the Work
as being Mechanically Complete in the manner set forth above, or notify Willbros in writing of still unfinished or uncorrected Exception Items. If Exception Items remain unfinished or uncorrected, the foregoing procedure shall be repeated until the
Work is Mechanically Complete. 

  

 A-23 

	8.2	Start-up: Willbros shall comply with all requirements needed to achieve Start-up, including as set forth in the definition of the term Start-up and elsewhere in this
Agreement. When Willbros believes Start-up has been achieved, Willbros shall certify to Cheniere in writing in the form of the Start-up Certificate attached hereto as Attachment V that all of the requirements for achieving Start-up have
occurred, including all documentation required to establish that the requirements for Start-up have been met. Within seven (7) days after receipt of such notice Cheniere shall inspect the Work and either accept the Work as having achieved
Start-up (which acceptance shall be evidenced by Cheniere’s signature on such Start-up Certificate), or specify the Exception Items which must be completed to achieve Start-up in a written notice to Willbros. Upon completion or correction of
such Exception Items, Willbros shall so advise Cheniere. Within seven (7) days after receipt of such notice, Cheniere shall either approve the Start-up of the Work in the manner set forth above, or notify Willbros in writing of still unfinished
or uncorrected Exception Items. If Exception Items remain unfinished or uncorrected, the foregoing procedure shall be repeated until Start-up is achieved. Notwithstanding the foregoing, if Cheniere has not commenced the introduction of either
natural gas or nitrogen in accordance with Paragraph 1.57 within thirty (30) days of achievement of Mechanical Completion, then Start-up shall be deemed achieved upon the expiration of such thirty (30) day period, provided that Willbros
has fully satisfied all other requirements for Start-up. 

  

	8.3	Project Completion: Willbros shall comply with all requirements for Project Completion, including as set forth in the definition of the term Project Completion and elsewhere
in this Agreement. When Willbros believes it has completed all obligations under this Agreement to achieve Project Completion, Willbros shall certify to Cheniere in writing in the form of the Project Completion Certificate as attached hereto as
Attachment IV that all of the requirements for achieving Project Completion have occurred, including all documentation required to establish that the requirements of Project Completion have been met. Within seven (7) days after receipt
of such notice Cheniere shall inspect the Work and either accept that Project Completion has been achieved (which acceptance shall be evidenced by Cheniere’s signature on such Project Completion Certificate), or specify the Exception Items
which must be completed to achieve Project Completion in a written notice to Willbros. Upon completion or correction of such Exception Items, Willbros shall so advise Cheniere. Within seven (7) days after receipt of such notice, Cheniere shall
either accept the Work as having achieved Project Completion in the manner set forth above, or notify Willbros in writing of still unfinished or uncorrected Exception Items. If Exception Items remain unfinished or uncorrected, the foregoing
procedure shall be repeated until Project Completion is achieved. 

  

	8.4	 No Waiver: No acceptance by Cheniere of any or all of the Work or any other obligations of Willbros under this Agreement, including acceptance of Mechanical
Completion, Start-up or Project Completion, nor any payment made hereunder, whether an interim or final payment, shall in any way release Willbros or any surety of Willbros or its Subcontractors from any obligations or liability pursuant to this
Agreement, including obligations with respect to unperformed obligations of this Agreement, obligations 

  

 A-24 

	 	 
regarding any remediation or other Work required pursuant to Paragraph 12, correction of any Work that does not conform to the requirements of the Agreement
or other Warranty obligations, and any liabilities for which insurance is required or any other responsibility of Willbros, including the payment of any and all fines and penalties assessed as a result of Willbros’ failure to comply with
Applicable Law. 

 9. CHANGES 
  

	9.1	Change Orders Requested by Cheniere: At any time upon written notice to Willbros from Cheniere, and without notice to the sureties, if any, Cheniere may advise Willbros to
make or agree with Willbros that there has been a Change to the Work, including the time and/or sequence of performance, or the conditions affecting the Work. All Work involved in a Change, as directed by a Change Order, shall be performed in
accordance with the terms and conditions of the Agreement and shall not otherwise affect the existing rights or obligations of the Parties (except as may be expressly stated in a Change Order). Cheniere shall specify, in the Change Order, the amount
and nature of Work to be done or omitted, the materials to be used and the equipment to be furnished. Willbros shall perform the Work as changed without delay. 

  

	9.2	Change Order Format: A Change in the Work shall be set forth in writing in a Change Order, using the form provided in Attachment VI, and signed by both Parties. Change
Orders shall include the adjustment, if necessary, in the Preparation and Material Receipt Commencement Date, the Scheduled Mechanical Completion Date, Construction Commencement Date or the Guaranteed Maximum Price. 

  

	9.3	Change Orders Act as Accord and Satisfaction: The Parties agree that Change Orders executed by Cheniere and Willbros shall constitute a full and final settlement and accord
and satisfaction of all effects of the Change upon any and all respects of this Agreement and the Work and shall compensate Willbros fully. Willbros expressly waives and releases any and all right to make a claim or demand or to take any action or
proceeding for any other consequences arising out of, relating to, or resulting from the Change reflected in the Change Order, whether the consequences result directly or indirectly from the Change reflected in that Change Order.

  

	9.4	 Adjustment Only Through Change Order: Willbros shall not perform a Change of any kind, except as authorized in a Change Order. Adjustments to the Guaranteed
Maximum Price, the Preparation and Material Receipt Commencement Date, the Construction Commencement Date or the Scheduled Mechanical Completion Date shall only be made by Change Order. No course of conduct or dealings between the Parties, nor
express or implied acceptance of additions, deletions, suspensions or modifications to this Agreement, the Drawings or the Specifications, including any Work, and no claim that Cheniere has been unjustly enriched by any such addition, deletion,
suspension or modification of this Agreement, the Drawings or the Specifications, whether or not there is in fact any such unjust enrichment, shall be the basis for any claim for an adjustment in the Guaranteed Maximum Price, the Preparation and
Material Receipt Commencement 

  

 A-25 

	 	 
Date, the Construction Commencement Date, the Scheduled Mechanical Completion Date or any other obligations of Willbros under this Agreement.

  

	9.5	Change Orders Requested by Willbros: Willbros shall give written notice to Cheniere of any requests, claims or proposals for adjustments to the Work, the Guaranteed Maximum
Price, the Preparation and Material Receipt Commencement Date, the Construction Commencement Date or the Scheduled Mechanical Completion Date for Changes directed by Cheniere or for circumstances otherwise permitted by this Agreement within the time
frame and in accordance with Paragraph 14.1. 

  

	9.6	Change Order Compensation: The cost or credit to Cheniere resulting from a Change in the Work shall in each instance be determined in accordance with one of more of the
following methods and specified in the Change Order: (i) by mutual acceptance of a properly itemized lump sum amount; or (ii) for Project management, engineering and drafting, procurement services and construction management services, by
unit prices or hourly rates set forth in Attachment II of the Letter Agreement or otherwise agreed upon by the Parties; or (iii) for construction work performed by Willbros RPI, Inc. (if such entity is the selected construction
Subcontractor), by unit prices or hourly rates set forth in Attachment III of the Letter Agreement or otherwise agreed upon by the Parties. If any of the Changes provided for in a Change Order increase the lump sum construction costs within
the Guaranteed Maximum Price, such increase shall be subject to Cheniere’s right to retainage as set forth in Paragraph 1.4.1 of the Letter Agreement. 

 10. INDEMNITY, LIENS AND PATENTS 
  

	10.1	General Indemnifications Notwithstanding any other provision to the contrary, Cheniere and Willbros agree as follows: 

  

	 	10.1.1 	INJURIES TO WILLBROS GROUP PERSONNEL AND DAMAGE TO
WILLBROS GROUP PROPERTY: WILLBROS HEREBY RELEASES, AND AGREES TO DEFEND,
INDEMNIFY, AND HOLD THE CHENIERE GROUP HARMLESS FROM AND AGAINST, ANY
AND ALL CLAIMS, DEMANDS, CAUSES OF ACTION, SUITS, LIABILITIES, LOSSES, DAMAGES
AND EXPENSES INCLUDING COURT COSTS AND REASONABLE ATTORNEY’S FEES
(COLLECTIVELY, “CLAIMS”) ARISING OUT OF OR RESULTING FROM (1) INJURY TO
OR DEATH OF THE WILLBROS GROUP PERSONNEL, OR (2) DAMAGE TO OR
DESTRUCTION OF THE WILLBROS GROUP PROPERTY, WHETHER OR NOT SUCH CLAIMS
ARE DUE TO AN ACT, OMISSION, NEGLIGENCE WHETHER CONTRIBUTORY, JOINT, OR
SOLE, FAULT OR STRICT LIABILITY OF THE CHENIERE GROUP, BUT EXCLUDING
ONLY THOSE CLAIMS DUE TO THE WILLFUL MISCONDUCT OF THE CHENIERE
GROUP. 

  

	 	10.1.2 	 THIRD PARTY INDEMNIFICATION: WILLBROS HEREBY
RELEASES, AND AGREES TO DEFEND, INDEMNIFY, AND HOLD CHENIERE GROUP HARMLESS
FROM AND AGAINST, ANY AND ALL CLAIMS ARISING OUT OF OR RESULTING
FROM DAMAGE TO OR DESTRUCTION OF PROPERTY OR PERSONAL INJURY TO OR
DEATH OF ANY THIRD PARTY (OTHER THAN A MEMBER OF THE CHENIERE
GROUP OR THE WILLBROS 

  

 A-26 

	 	 
GROUP) TO THE EXTENT ARISING OUT OF
OR RESULTING FROM WILLBROS’ OR ITS SUBCONTRACTORS’ OR VENDORS’ PERFORMANCE
OF THE WORK, INCLUDING THE BREACH OF THIS AGREEMENT BY WILLBROS AND
THE NEGLIGENCE, GROSS NEGLIGENCE OR WILLFUL MISCONDUCT OF WILLBROS, ITS
SUBCONTRACTORS, ITS VENDORS OR ANYONE EMPLOYED BY THEM OR ANYONE FOR
WHOSE ACTS THEY MAY BE LIABLE. 

  

	 	10.1.3 	INJURIES TO CHENIERE GROUP PERSONNEL AND DAMAGE TO
CHENIERE GROUP PROPERTY: CHENIERE HEREBY RELEASES, AND AGREES TO DEFEND,
INDEMNIFY, AND HOLD THE WILLBROS GROUP HARMLESS FROM AND AGAINST, ANY
AND ALL CLAIMS ARISING OUT OF OR RESULTING FROM (1) INJURY TO OR
DEATH OF THE CHENIERE GROUP PERSONNEL, OR (2) DAMAGE TO OR DESTRUCTION
OF THE CHENIERE GROUP PROPERTY (EXCLUDING THE WORK OR THE PROJECT),
WHETHER OR NOT SUCH CLAIMS ARE DUE TO AN ACT, OMISSION, NEGLIGENCE
WHETHER CONTRIBUTORY, JOINT, OR SOLE, FAULT OR STRICT LIABILITY OF THE
WILLBROS GROUP, BUT EXCLUDING ONLY THOSE CLAIMS DUE TO THE WILLFUL
MISCONDUCT OF THE WILLBROS GROUP. 

  

	 	10.1.4 	HAZARDOUS SUBSTANCES INDEMNIFICATION: WILLBROS HEREBY RELEASES,
AND AGREES TO DEFEND, INDEMNIFY AND HOLD CHENIERE GROUP HARMLESS FROM
ANY AND ALL CLAIMS, FINES, PENALTIES OR REMEDIATION OBLIGATIONS ARISING OUT
OF OR RESULTING FROM (A) ACTUAL OR ALLEGED POLLUTION OR CONTAMINATION
OF THE LAND, WATER OR AIR ARISING FROM SPILLS, RELEASES, DISCHARGES
OR OTHERWISE OF HAZARDOUS SUBSTANCES, INCLUDING FUELS, LUBRICANTS, MOTOR OILS, PIPE
DOPE, PAINTS, SOLVENTS, AND GARBAGE, USED, HANDLED OR DISPOSED OF BY
WILLBROS OR ITS SUBCONTRACTORS OR VENDORS DURING THE PERFORMANCE OF THE
WORK, AND (B) ANY ENVIRONMENTAL DAMAGE OF ANY OTHER NATURE TO
THE EXTENT RESULTING FROM THE PERFORMANCE OF THE WORK BY WILLBROS OR
ITS SUBCONTRACTORS OR VENDORS; PROVIDED, HOWEVER, THAT WILLBROS SHALL HAVE NO
LIABILITY OR RESPONSIBILITY FOR ANY POLLUTION, CONTAMINATION OR ENVIRONMENTAL DAMAGE
EXISTING AT THE WORK SITE PRIOR TO THE COMMENCEMENT OF THE WORK.

  

	 	10.1.5 	COMPLIANCE WITH APPLICABLE LAW INDEMNIFICATION: WILLBROS
HEREBY RELEASES, AND AGREES TO DEFEND, INDEMNIFY AND HOLD CHENIERE GROUP
HARMLESS FROM ANY AND ALL CLAIMS, FINES, PENALTIES OR REMEDIATION OBLIGATIONS
TO THE EXTENT ARISING OUT OF OR RESULTING FROM WILLBROS’ OR ITS
SUBCONTRACTORS’ OR VENDORS’ ACTUAL OR ALLEGED FAILURE TO COMPLY WITH
APPLICABLE LAW OR APPLICABLE CODES AND STANDARDS, OR ANY JUDICIAL ARBITRAL
OR REGULATORY INTERPRETATION THEREOF. 

  

	 	10.1.6 	 WAIVER OF CONSEQUENTIAL DAMAGES: NOTWITHSTANDING ANY
OTHER PROVISIONS IN THIS AGREEMENT TO THE CONTRARY, IN NO EVENT SHALL
ANY ENTITY IN EITHER CHENIERE GROUP OR THE WILLBROS GROUP BE LIABLE,
ONE TO THE OTHER, FOR INDIRECT, SPECIAL, INCIDENTAL OR CONSEQUENTIAL DAMAGES,

  

 A-27 

	 	 
INCLUDING LOSS OF PROFITS, LOSS OF USE
OF ASSETS, OR BUSINESS INTERRUPTION UNDER THIS AGREEMENT OR ANY CAUSE
OF ACTION RELATED THERETO, PROVIDED THAT THE LIMITATION OF LIABILITY SET
FORTH IN THIS PARAGRAPH 10.1.6 SHALL NOT APPLY TO (A) WILLBROS’
CONFIDENTIALITY OBLIGATIONS AS PROVIDED BY THIS AGREEMENT; (B) WILLBROS’ INDEMNIFICATION
OBLIGATIONS FOR THIRD PARTY CLAIMS UNDER THIS AGREEMENT; (C) THE AMOUNTS
ENCOMPASSED WITHIN THE LIQUIDATED DAMAGES PROVIDED FOR IN PARAGRAPH 21; OR
(D) AS EXPRESSLY PERMITTED UNDER PARAGRAPH 21.2. 

  

	10.2	LIEN INDEMNIFICATION: WITHOUT IN ANY WAY LIMITING
THE FOREGOING, SO LONG AS CHENIERE REMITS UNDISPUTED PAYMENTS TO WILLBROS
WHEN DUE UNDER THIS AGREEMENT, WILLBROS HEREBY RELEASES, AND AGREES TO
DEFEND, INDEMNIFY AND HOLD CHENIERE GROUP HARMLESS FROM, AND SHALL KEEP
THE WORK, THE WORK SITE AND THE PROJECT FREE AND CLEAR OF,
ANY AND ALL LIENS AND ENCUMBRANCES ASSERTED BY AN ENTITY ACTING
THROUGH WILLBROS, ANY SUBCONTRACTOR, ANY VENDOR OR ANY OTHER PERSON OR
ENTITY ACTING THROUGH OR UNDER ANY OF THEM. IF WILLBROS FAILS TO
DISCHARGE SUCH LIEN OR ENCUMBRANCE OR POST ADEQUATE SECURITY WITH RESPECT
THERETO WITHIN THIRTY (30) DAYS OF THE FILING OF SUCH LIEN OR
ENCUMBRANCE, CHENIERE, IF IT SO ELECTS, MAY DISCHARGE ANY SUCH LIENS
OR ENCUMBRANCES, AND WILLBROS SHALL BE LIABLE TO CHENIERE FOR ALL
DAMAGES, COSTS, LOSSES, AND EXPENSES (INCLUDING ALL ATTORNEYS’ FEES, CONSULTANT
FEES AND LITIGATION OR ARBITRATION EXPENSES) INCURRED BY CHENIERE ARISING OUT
OF OR RELATING TO SUCH DISCHARGE OR RELEASE. THEREAFTER, CHENIERE MAY
INVOICE WILLBROS FOR SUCH AMOUNT OWED (WHICH INVOICE SHALL BE PAID BY
WILLBROS WITHIN THIRTY (30) DAYS AFTER RECEIPT THEREOF) OR DEDUCT THE AMOUNT
SO PAID BY CHENIERE FROM SUMS DUE OR WHICH THEREAFTER BECOME DUE
TO WILLBROS HEREUNDER. 

  

	10.3	 PATENT AND COPYRIGHT INDEMNIFICATION: WILLBROS
HEREBY RELEASES, AND AGREES TO DEFEND, INDEMNIFY AND HOLD CHENIERE GROUP
HARMLESS FROM ANY CLAIMS TO THE EXTENT ARISING FROM OR RELATING TO
THE ACTUAL OR ALLEGED INFRINGEMENT OF ANY DOMESTIC OR FOREIGN PATENTS,
COPYRIGHTS, TRADEMARKS OR OTHER INTELLECTUAL PROPERTY RIGHTS THAT MAY BE
ATTRIBUTABLE TO WILLBROS OR ITS SUBCONTRACTORS OR VENDORS IN CONNECTION WITH
THE WORK. IN THE EVENT THAT ANY SUIT, CLAIM, TEMPORARY RESTRAINING
ORDER OR PRELIMINARY INJUNCTION IS GRANTED IN CONNECTION WITH THIS PARAGRAPH 10.3,
WILLBROS SHALL, IN ADDITION TO ITS OBLIGATION ABOVE, MAKE EVERY REASONABLE
EFFORT, BY GIVING A SATISFACTORY BOND OR OTHERWISE, TO SECURE THE
SUSPENSION OF THE INJUNCTION OR RESTRAINING ORDER. IF, IN ANY SUCH
SUIT OR CLAIM, THE WORK, THE PROJECT OR ANY PART, COMBINATION OR
PROCESS THEREOF, IS HELD TO CONSTITUTE AN INFRINGEMENT AND ITS USE IS
PRELIMINARILY OR PERMANENTLY ENJOINED, WILLBROS SHALL PROMPTLY MAKE EVERY REASONABLE
EFFORT TO SECURE FOR CHENIERE A LICENSE, AT NO COST TO CHENIERE,
AUTHORIZING CONTINUED USE OF THE INFRINGING WORK. IF WILLBROS IS UNABLE
TO SECURE SUCH A LICENSE WITHIN A REASONABLE TIME, WILLBROS SHALL, AT
ITS OWN EXPENSE AND WITHOUT IMPAIRING PERFORMANCE REQUIREMENTS, EITHER REPLACE THE

  

 A-28 

	 	 
AFFECTED WORK, IN WHOLE OR PART, WITH
NON-INFRINGING COMPONENTS OR PARTS OR MODIFY THE SAME SO THAT THEY
BECOME NON-INFRINGING. 

  

	10.4	ATTORNEYS’ FEES: EACH PARTY AGREES TO REIMBURSE
THE PREVAILING PARTY FOR ANY AND ALL NECESSARY EXPENSES, ATTORNEY’S
FEES, AND RELATED COSTS INCURRED IN THE ENFORCEMENT OF ANY PART OF
THE INDEMNITY AGREEMENTS PROVIDED FOR HEREIN. 

  

	10.5	Enforceability: 

  

	 	10.5.1 	Exclusions to Liability and Indemnity: Except as expressly provided elsewhere in this Agreement, the exclusions of liability and indemnities herein shall apply according to
their terms to any such Claim, loss, damage, expense, injury, illness or death, without regard to the cause thereof, including strict liability, ultra hazardous activity, breach of express or implied warranty, imperfection of material, defect or
failure of equipment, defect or “ruin” or other condition of premises, or the sole or concurrent negligence or other fault of the party being indemnified. 

  

	 	10.5.2 	CONCURRENT NEGLIGENCE: EXCEPT AS OTHERWISE SET FORTH
IN PARAGRAPHS 10.1.1 AND 10.1.3, THE INDEMNITY, DEFENSE AND HOLD HARMLESS OBLIGATIONS
FOR PERSONAL INJURY OR DEATH OR PROPERTY DAMAGE UNDER THIS AGREEMENT
SHALL APPLY REGARDLESS OF WHETHER THE INDEMNIFIED PARTY WAS CONCURRENTLY NEGLIGENT
(WHETHER ACTIVELY OR PASSIVELY), IT BEING AGREED BY THE PARTIES THAT
IN THIS EVENT, THE PARTIES’ RESPECTIVE LIABILITY OR RESPONSIBILITY FOR SUCH
DAMAGES, LOSSES, COSTS AND EXPENSES UNDER THIS PARAGRAPH 10 SHALL BE DETERMINED
IN ACCORDANCE WITH PRINCIPLES OF COMPARATIVE NEGLIGENCE. 

  

	 	10.5.3 	Louisiana Oilfield Anti-Indemnity Act: Willbros and Cheniere agree that the Louisiana Oilfield Anti-Indemnity Act, LA. REV. STAT.
§ 9:2780, ET. SEQ., is inapplicable to this Agreement and the performance of the Work. Application of these code sections to this Agreement would be contrary to the intent of the Parties, and each Party hereby
irrevocably waives any contention that these code sections are applicable to this Agreement or the Work. In addition, it is the intent of the Parties in the event that the aforementioned act were to apply that each Party shall provide insurance to
cover the losses contemplated by such code sections and assumed by each such Party under the indemnification provisions of this Agreement, and Willbros agrees that the payments made to Willbros hereunder compensate Willbros for the cost of premiums
for the insurance provided by it under this Agreement. The Parties agree that each Party’s agreement to support their indemnification obligations by insurance shall in no respect impair their indemnification obligations.

  

	 	10.5.4 	 Conflict with Applicable Law: In the event that any indemnity provisions in this Agreement are contrary to the law governing this Agreement, then the
indemnity 

  

 A-29 

	 	 
obligations applicable hereunder shall be applied to the maximum extent allowed by Applicable Law. 

 11. INSURANCE 
  

	11.1	Willbros’ Insurance: All insurance obtained pursuant to this Agreement shall: (1) be issued by insurers with an “A-X” or better A.M. Best Co. rating in
the current Property-Casualty Edition and authorized to do business in the state in which the Project is located, and (2) be in all other respects acceptable to Cheniere. Willbros shall carry and maintain or cause to be carried and maintained
in force at all times during the term of the Agreement the following insurance: 

  

	 	11.1.1 	Workers’ Compensation/Employers’ Liability 

 Workers’ compensation with appropriate longshoremen’s or harbor workers’ endorsement (if applicable) covering all Willbros Personnel in accordance with the statutory requirements of the state of hire or country in which the
Work is to be performed, and if the Work includes the use of vessels, appropriate maritime extensions. Employers’ liability insurance with the limit of One Million United States Dollars (U.S. $l,000,000) per accident or illness. 
  

	 	11.1.2 	Commercial General Liability 

 Commercial general
liability insurance with contractual liability, products and completed operations, and broad form property damage coverage included, which shall provide for a combined single limit of One Million United States Dollars (U.S. $1,000,000) for personal
injury, death or property damage resulting from each occurrence and covering all of Willbros’ Work under the Agreement; provided, however, this coverage requirement may be satisfied by Willbros through any combination of primary and excess
liability insurance. 
  

	 	11.1.3 	Automobile Liability 

 Automobile liability
insurance covering owned, non-owned and hired motor vehicles, with combined single limits of at least One Million United States Dollars (U.S. $1,000,000) for personal injury, death, or property damage resulting from each occurrence. 
  

	 	11.1.4 	Aircraft Liability Insurance 

 Aircraft liability
insurance, to the extent applicable, covering owned, non-owned and hired aircraft with a combined single limit of Five Million United States Dollars (U.S. $5,000,000) for bodily injury, death and property damage resulting from each occurrence.

  

 A-30 

	 	11.1.5 	Transportation Insurance 

 “All Risk”
Insurance covering the full replacement cost of all supplies, equipment and materials to be incorporated into the Work while in the course of transit, including the land portion of any ocean or air shipments, and until arrival at the final local
Work Sites. Such transit insurance shall include coverage against the perils of war, strikes, riots and civil commotion and shall insure all general average and salvage charges for which named insureds are responsible. Such insurance shall have a
deductible of Fifty Thousand United States Dollars (U.S. $50,000) per loss. 
  

	 	11.1.6 	Builder’s Risk Insurance 

 Completed value form
builder’s risk property insurance (subject to a deductible per loss not to exceed $50,000) upon the entire Work for one hundred percent (100%) of the full replacement cost value thereof (100% includes additional costs of engineering
services in the event of a loss). This policy shall include the interests of Cheniere Group and Willbros Group in the Work as named insureds, as their interests may appear, shall name Cheniere as the loss payee, and shall be on an “All
Risk” basis for physical loss or damage including fire, flood, earthquake, subsidence, hail, theft, vandalism and malicious mischief and shall include coverage for portions of the Work while it is stored off the Work Site or is in transit
(except as otherwise covered by Paragraph 11.1.5). This policy shall provide, by endorsement or otherwise, that Willbros shall be solely responsible for the payment of all premiums under the policy, and that the Cheniere Group shall have no
obligation for the payment thereof, notwithstanding that the Cheniere Group are named insureds under the policy. Willbros shall be responsible for any loss within the deductible of the policy for the liabilities assumed by Willbros hereunder.

  

 A-31 

	 	11.1.7 	Errors and Omissions Insurance 

 Errors and
Omissions Professional Liability Insurance (“E&O Insurance”) having minimum limits of Five Million United States Dollars (U.S.$5,000,000) per claim and in the aggregate, with a deductible not in excess of Two Hundred Fifty Thousand
United States Dollars (U.S.$250,000) per claim and in the aggregate, on a claims made basis. E&O Insurance shall cover liability arising out of or based upon any negligent design, engineering or other professional services performed by Willbros
or any of its Subcontractors which is required as or associated with any part of the Work. The E&O Insurance shall have a retroactive date prior to the performance of any Work to be provided under this Agreement, shall have a policy period or
renewal period extending through the termination or expiration of this Agreement and for two (2) years thereafter, and shall state that in the event of cancellation or non-renewal, the discovery period for insurance claims (tail coverage) shall
be at least thirty-six (36) months. 
  

	 	11.1.8 	Excess Liability Insurance 

 Umbrella or excess
liability insurance, written on a “following form” basis and providing coverage in excess of the coverages required to be provided by Willbros for employer’s liability insurance, commercial general liability insurance and automobile
liability insurance, with limits of Twenty-Five Million United States Dollars (U.S.$25,000,000) combined single limit each claim and in the aggregate. 
  

	11.2	Notice: Willbros shall have the insurance carriers furnish to Cheniere, upon the Effective Date and annually thereafter, insurance certificates specifying the types and
amounts of coverage in effect and the expiration dates of each policy, and a statement that no insurance will be canceled or materially changed without thirty (30) days prior written notice to Cheniere. 

  

	11.3	Waiver of Subrogation: All policies of insurance required to be provided by Willbros under this Agreement shall include clauses providing that each underwriter shall waive
its rights of recovery, under subrogation or otherwise, against the Cheniere Group for the liabilities assumed by Willbros hereunder. Insurance policies pursuant to Paragraphs 11.1.2, 11.1.3, 11.1.4, 11.1.5, 11.1.6 and 11.1.8 shall designate
Cheniere as additional insured for the liabilities assumed by Willbros hereunder, and that the policies provided by Willbros shall be primary and noncontributing to any insurance carried by Cheniere with regard to the liabilities assumed by Willbros
hereunder. The policies referred to in Paragraphs 11.1.2 and 11.1.3 shall contain a cross-liability clause in respect of third party claims so that Cheniere and Willbros are regarded as third parties as to each other. 

  

	11.4	 Obligations Not Relieved: Except as otherwise provided in this Agreement to the contrary, the occurrence of any of the following shall in no way relieve
Willbros from any of its obligations under this Agreement: (i) failure by Willbros to secure or maintain the insurance coverage required hereunder; (ii) failure by Willbros to comply fully with any 

  

 A-32 

	 	 
of the insurance provisions of this Agreement; (iii) failure by Willbros to secure such endorsements on the policies as may be necessary to carry out
the terms and provisions of this Agreement; (iv) the insolvency, bankruptcy or failure of any insurance company providing insurance to Willbros; (v) failure of any insurance company to pay any claim accruing under its policy; or
(vi) losses by Willbros or any of its Subcontractors or Vendors not covered by insurance policies. 

  

	11.5	Subcontractors’ and Vendors’ Insurance: If Willbros subcontracts any part of the Work, Willbros shall obtain or require its Subcontractors and Vendors to maintain,
the same insurance coverage and amounts that Willbros is required to maintain pursuant to this Paragraph 11, as applicable and appropriate to the Work of such Subcontractor or Vendor. 

  

	11.6	Parent Guarantee: Willbros will guarantee the full and faithful performance of all obligations of Willbros under this Agreement by providing Cheniere with a parent guarantee
in the form attached as Attachment I. 

  

	11.7	Performance and Payment Bonds: Prior to commencement of the construction component of the Work and in any event no later than thirty (30) days prior to Cheniere’s
payment to Willbros of the down payment for such Work in accordance with Paragraph 1.4.1(i) of Attachment I to the Letter Agreement, Willbros shall cause the construction Subcontractor to provide to Cheniere and maintain performance and
payment bonds in the form of Attachment II and in an amount equal to the amount of the cost of construction, as indicated in the Schedule of Values. Such bonds shall be provided by a surety licensed to transact business in the State of
Louisiana, U.S. Department of Treasury listed and otherwise approved by Cheniere, which approval shall not be unreasonably withheld. Each bond shall also attach the respective dual obligee riders set forth in Attachment II, naming
Cheniere as a dual obligee under each bond. The premium of such bonds shall be reimbursed to Willbros by Cheniere and shall be included in the Guaranteed Maximum Price. 

  

	11.8	 Limitation of Liability. Notwithstanding any other provision of this Agreement, under no circumstance shall the liability of Willbros to Cheniere in
connection with the Work exceed in the cumulative aggregate fifteen percent (15%) of the cost of construction, as indicated in the Schedule of Values and as may be adjusted by Change Order, provided that, notwithstanding the foregoing, the
limitation of liability set forth in this Paragraph 11.8 shall not (i) apply in the event of Willbros’ willful misconduct (including the willful refusal to perform the Work, willful delay in performing the Work or abandonment of the Work)
or gross negligence; (ii) apply to Willbros’ indemnification obligations under this Agreement; or (iii) include the payment of proceeds under any insurance policy required to be provided by Willbros under Paragraph 11.1, Cheniere or
any Subcontractor or Vendor. In no event shall the limitation of liability set forth in this Paragraph 11.8 be in any way deemed to limit Willbros’ obligation to perform all Work required to achieve Mechanical Completion, Start-up and Project
Completion. The costs incurred by Willbros in performing the Work (including Corrective Work and other Warranty 

  

 A-33 

	 	 
obligations but excluding the payment of Liquidated Damages) shall not be counted against the aggregate limitation of liability set forth in this Paragraph
11.8. 

 12. WARRANTY 
  

	12.1	General: Any Work, or component thereof, that is not in conformity with any warranties set forth in this Paragraph 12 and elsewhere in this Agreement (collectively, the
“Warranty” or “Warranties”) is defective (“Defective”) and contains a defect (“Defect”). Willbros hereby warrants that the Work and each component thereof shall be: 

  

	 	12.1.1 	new, complete, fit for the purposes specified in this Agreement and of suitable grade for the intended function and use; 

  

	 	12.1.2 	in accordance with all of the requirements of this Agreement, including in accordance with good engineering and construction practices, Applicable Law and Applicable Codes and
Standards; 

  

	 	12.1.3 	free from encumbrances to title, as set forth in greater detail in Paragraph 10.2; and 

  

	 	12.1.4 	free from defects in design, material and workmanship and otherwise conform to the standards and requirements contained in the Specifications and elsewhere in this Agreement.

 Willbros and its Subcontractors and Vendors shall exercise that high degree of skill and judgment normally exercised by firms
performing services of a similar nature. 
  

	12.2	Correction of Work: 

  

	 	12.2.1 	Prior to Start-up: Willbros’ obligations to correct Work prior to Start-up are set forth in Paragraph 7.4. 

  

	 	12.2.2 	 After Start-up: If within twelve (12) months after Start-up (the “Defect Correction Period”) any Work is found to be Defective, Willbros
shall, at its sole cost and expense, immediately and on an expedited basis correct such Defective Work and any other portions of the Project damaged or affected by such Defective Work, whether by repair, replacement or otherwise (“Corrective
Work”) and shall be liable for and pay to Cheniere any and all costs, losses, damages and expenses incurred by Cheniere arising out of or relating to such Defective Work. Cheniere shall provide Willbros with access to the Project sufficient to
perform its Corrective Work, so long as such access does not unreasonably interfere with operation of the Project and subject to any reasonable security or safety requirements of Cheniere. In the event Willbros utilizes spare parts owned by Cheniere
in the course of performing the Corrective Work, Willbros shall supply Cheniere free of charge with new spare parts equivalent in quality and quantity to 

  

 A-34 

	 	 
all such spare parts used by Willbros as soon as possible following the utilization of such spare parts. 

  

	 	12.2.3 	Cheniere’s Right to Correct or Complete Defective Work: If Willbros fails to commence the Corrective Work within a reasonable period of time not to exceed forty-eight
(48) hours, or does not complete such Corrective Work on an expedited basis, then Cheniere, by written notice to Willbros, may (without prejudice to any other remedies that it may have under this Agreement) correct such Defective Work, and
Willbros shall be liable to Cheniere for all costs, losses, damages and expenses incurred by Cheniere in connection with correcting such Defective Work and arising out of or relating to such Defective Work and shall pay Cheniere (directly, or by
offset, at Cheniere’s sole discretion) an amount equal to such costs, losses, damages and expenses; provided, however, if such Defective Work presents an imminent threat to the safety or health of any person and Cheniere knows of such Defective
Work, Cheniere may (without prejudice to any other remedies that it has under this Agreement) correct such Defective Work without giving prior written notice to Willbros, and, in that event, Willbros shall be liable to Cheniere for all reasonable
costs, losses, damages and expenses incurred by Cheniere in connection with correcting such Defective Work and arising out of or relating to such Defective Work and shall pay Cheniere (directly or by offset, at Cheniere’s sole discretion) an
amount equal to such costs, losses, damages and expenses. 

  

	 	12.2.4 	Extended Defect Correction Period for Corrective Work: With respect to any Corrective Work performed, the Defect Correction Period for such Corrective Work shall be extended
for an additional twelve (12) months from the date of the completion of such Corrective Work; provided, however, in no event shall the Defect Correction Period for such Corrective Work be less than the original Defect Correction Period. In no
event shall the Defect Correction Period plus any extended Defect Correction Period exceed a total period of twenty-four (24) months. 

  

	 	12.2.5 	Standards for Corrective Work: All Corrective Work shall be performed subject to the same terms and conditions under this Agreement as the original Work is required to be
performed. 

  

	 	12.2.6 	 No Limitation: Nothing contained in this Paragraph 12.2 shall be construed to establish a period of limitation with respect to other obligations which
Willbros might have under the Agreement. Establishment of the Defect Correction Period relates only to the specific obligation of Willbros to perform Corrective Work, and has no relationship to the time within which the obligation to comply with
this Agreement may be sought to be enforced, nor to the time within which proceedings may be commenced to establish Willbros’ liability with respect to Willbros’ obligations other than specifically to perform Corrective Work. In addition,
all representations, Warranties and obligations to perform Corrective 

  

 A-35 

	 	 
Work set forth in this Agreement, including those in this Paragraph 12, shall be in addition to and shall in no way limit Willbros’ obligation to
perform all Work necessary to achieve Project Completion. 

  

	 	12.2.7 	Vendor Correction of Work Warranties for Materials or Equipment: Notwithstanding anything to the contrary in this Agreement, with respect to any materials or equipment
procured by Willbros from a Vendor, Willbros’ liability during the Defect Correction Period for such materials and equipment shall be limited to “passing through” to Cheniere the benefits of any correction of Work warranty received
from the applicable Vendor, which correction of Work obligation shall be deemed to run to the benefit of Cheniere. Willbros shall use its best efforts to obtain a correction of Work warranty identical to Willbros’ correction of Work obligations
set forth in Paragraph 12.2.2, but in no event shall such correction of Work obligations be less than industry standard and otherwise reasonable to protect Cheniere from Defective Work. Willbros shall use its best efforts to cause such Vendors to
perform their obligations under such warranties, and shall cooperate with Cheniere’s efforts to enforce such warranties with any such Vendors. Willbros shall assign in full, and without cost to Cheniere, all such warranties from such Vendors.
In the event of a Dispute during the Defect Correction Period as to whether Defective Work relates to a Defect in workmanship (and, therefore, is covered by Paragraph 12.2.2) or a Defect in material or equipment provided by a Vendor (and, therefore,
is covered by this Paragraph 12.2.7), anything in this Paragraph notwithstanding, Willbros shall, at Cheniere’s direction and subject to the dispute resolution procedure set forth in Article 14, perform Corrective Work during the Defect
Correction Period unless Willbros successfully causes such Vendor to perform its correction of Work obligations in accordance with the terms of the applicable purchase order. 

  

	12.3	 Assignment and Enforcement of Subcontractor Warranties: Willbros shall, without additional cost to Cheniere, obtain Warranties from Subcontractors that meet
or exceed the requirements of this Agreement; provided, however, Willbros shall not in any way be relieved of its responsibilities and liability to Cheniere under this Agreement, regardless of whether such Subcontractor Warranties meet the
requirements of this Agreement, as Willbros shall be fully responsible and liable to Cheniere for its Warranty and corrective Work obligations and liability under this Agreement for all Work. All such Warranties shall be deemed to run to the benefit
of Cheniere and Willbros. Such Warranties, with duly executed instruments assigning the Warranties to Cheniere, shall be delivered to Cheniere upon Start-up. All Warranties provided by any Subcontractor shall be in such form as to permit direct
enforcement by Willbros or Cheniere against any Subcontractor whose Warranty is called for, and Willbros agrees that: (i) Willbros’ Warranty, as provided under this Paragraph 12 shall apply to all Work regardless of the provisions of any
Subcontractor Warranty, and such Subcontractor Warranties shall be in addition to, and not a limitation of, such Willbros Warranty; (ii) Willbros is jointly and severally liable with such Subcontractor with respect to such Subcontractor
Warranty; and (iii)

  

 A-36 

	 	 
service of notice on Willbros that there has been a breach of a Subcontractor Warranty shall be sufficient to invoke the terms of the instrument.

  

	12.4	Survival of Warranties: All representations and Warranties set forth in this Agreement, including those in this Paragraph 12, shall survive Project Completion or the earlier
termination of this Agreement. 

 13. TITLE TO THE WORK AND TO WORK PRODUCT, 
 CONFIDENTIAL INFORMATION 
  

	13.1	Title: The title to all or any portion of the Work (other than Work Product) shall pass to Cheniere upon the earlier of (a) payment by Cheniere therefore, or
(b) incorporation of such Work into the Work Site. Notwithstanding the foregoing, title to all materials furnished by Cheniere, irrespective of the location thereof, as between Cheniere and Willbros or any Subcontractor or Vendor, shall be in
Cheniere. Transfer of title to Work shall be irrespective of the passage of risk of loss pursuant to Paragraph 13.2 and shall be without prejudice to Cheniere’s right to reject Defective Work or any other right in this Agreement.

  

	13.2	Risk of Loss: Notwithstanding passage of title pursuant to Paragraph 13.1, Willbros shall bear the risk of loss and damage to Work until the earlier of Start-up or
termination of this Agreement; provided that Cheniere shall at all times bear the risk of physical loss and damage if and to the extent arising from (i) war (whether declared or undeclared), civil war, act of terrorism, sabotage, blockade,
insurrection; or (ii) ionizing radiation, or contamination by radioactivity from nuclear fuel, or from any nuclear waste from the combustion of nuclear fuel properties of any explosive nuclear assembly or nuclear component thereof. In the event
that any physical loss or damage to the Work arises from one or more of the events set forth in the preceding sentence, and Cheniere elects to rebuild such physical loss or damage, Willbros shall be entitled to a Change Order to the extent such
event adversely affects (i) Willbros’ costs of performance of the Work; (ii) Willbros’ ability to perform the Work in accordance with the Work Plan or (iii) Willbros’ ability to perform any material obligation under
this Agreement; provided that Willbros complies with the requirements set forth in Paragraphs 9.5 and 14.1. 

  

	13.3	 Ownership of Work Product: Subject to Paragraph 13.4, all materials which Willbros or any Subcontractor or Vendor is required to furnish, prepare or develop
in the performance and completion of Work hereunder (whether delivered to Cheniere or not), including reports, plans, Drawings and Specifications, calculations, maps, sketches, notes, data and samples (collectively, “Work Product”), shall
be “works for hire,” and all rights, title and interests to the Work Product, including any and all copyrights in the Work Product, shall be the sole and exclusive property of Cheniere without limitation (except Willbros may retain a copy
thereof in accordance with this Agreement), subject only to Willbros’ right to use the same to perform the Work. Such Work Product (including all copies thereof) shall, together with any materials furnished by Cheniere hereunder, be delivered
to Cheniere upon request and in any event upon completion or termination of this 

  

 A-37 

	 	 
Agreement. All such Work Product shall be considered to be Cheniere’s Confidential Information and is subject to the confidentiality obligations in
Paragraph 13.6. If for any reason any part of or all of the Work Product is not considered work for hire for Cheniere or if ownership of all right, title and interest in the Work Product shall not otherwise vest in Cheniere, then Willbros agrees
that such ownership and copyrights in the Work Product, whether or not such Work Product is fully or partially complete, shall be automatically assigned from Willbros to Cheniere, without further consideration, and Cheniere shall thereafter own all
right, title and interest in the Work Product, including all copyright interests. 

  

	13.4	Willbros Intellectual Property: As between Cheniere and Willbros, Willbros shall retain ownership of any intellectual property rights owned by Willbros or developed by
Willbros outside this Agreement and prior to the Effective Date (“Willbros’ Intellectual Property”). To the extent any Willbros’ Intellectual Property is incorporated, in whole or in part, into the Work Product, Willbros shall
provide prior written notice thereof to Cheniere. Cheniere shall be entitled to use Willbros’ Intellectual Property and Willbros hereby grants Cheniere an irrevocable and royalty-free license to use and modify Willbros’ Intellectual
Property for the sole purposes of: (i) operating and maintaining the Project; (ii) assisting in the performance of the Work; or (iii) repairing, replacing, expanding, completing or modifying any portion of the Work or the Project.
Cheniere shall be entitled to assign its rights in such license, provided that such assignee shall only use such license for the purposes specified in (i) through (iii) above. 

  

	13.5	Cheniere’s Use of the Work Product and Willbros’ Intellectual Property for Other Projects: In addition to the license granted in Paragraph 13.4, Cheniere shall be
entitled to use the Work Product and Willbros hereby grants solely to Cheniere an irrevocable and royalty-free license, non-transferable and non-assignable (except as set forth below) to use Willbros’ Intellectual Property embedded in the Work
Product, in each case solely for the purpose of developing other projects owned in whole or part by Cheniere, including the Corpus Christi and Creole Trail projects, provided that (i) Cheniere shall first remove all references to Willbros and
the Project from the Work Product and Willbros’ Intellectual Property embedded in the Work Product, (ii) the use of any of Willbros’ Intellectual Property on such other projects shall be limited to such Willbros’ Intellectual
Property which is embedded in the Work Product; and (iii) Cheniere shall not assign (except to an affiliated company of Cheniere) such Work Product or license without Willbros’ consent, which consent shall not be unreasonably withheld or
delayed. CHENIERE SHALL DEFEND, INDEMNIFY AND HOLD WILLBROS HARMLESS FROM AND AGAINST ALL DAMAGES, LOSSES, COSTS AND EXPENSES (INCLUDING ALL REASONABLE ATTORNEYS’ FEES AND LITIGATION OR ARBITRATION EXPENSES) INCURRED BY WILLBROS AND CAUSED BY
USE OF THE WORK PRODUCT OR WILLBROS’ INTELLECTUAL PROPERTY IN CONNECTION WITH PROJECTS OTHER THAN THE PROJECT WHICH IS THE SUBJECT OF THIS AGREEMENT. 

  

 A-38 

	13.6	Willbros’ Confidentiality Obligations: Willbros hereby covenants and warrants that Willbros and its employees and agents shall not (without in each instance obtaining
Cheniere’s prior written consent) disclose, make commercial or other use of, or give or sell to any person or entity any of the following information: (i) any Work Product other than to Subcontractors or Vendors as necessary to perform the
Work or (ii) any other information relating to the business, products, services, research or development, clients or customers of Cheniere or any member of the Cheniere Group, or relating to similar information of a third party who has
entrusted such information to Cheniere or any member of the Cheniere Group (hereinafter individually or collectively, “Cheniere’s Confidential Information”). Prior to disclosing any information in (i) of this Paragraph 13.6 to
any Subcontractor or Vendor as necessary to perform the Work, Willbros shall bind such Subcontractor or Vendor to the confidentiality obligations contained in this Paragraph 13.6 and to the term in Paragraph 13.11. Nothing in this Paragraph 13.6 or
this Agreement shall in any way prohibit Willbros or any of its Subcontractors or Vendors from making commercial or other use of, selling, or disclosing any of their respective Willbros’ Intellectual Property. 

  

	13.7	Cheniere’s Confidentiality Obligations: Cheniere hereby covenants and warrants that Cheniere and its employees and agents shall not (without in each instance obtaining
Willbros’ prior written consent) disclose, make commercial or other use of, or give or sell to any person or entity any pricing methodologies or pricing information (other than the Guaranteed Maximum Price or actual expenditures made by
Willbros under this Agreement) relating to the Work, which is conspicuously marked and identified in writing as confidential by Willbros (hereinafter individually or collectively, “Willbros’ Confidential Information”). The Parties
agree that Cheniere may disclose Willbros’ Confidential Information to any member of the Cheniere Group, underwriters, a bona fide prospective purchaser of all or a portion of Cheniere’s or any member of the Cheniere Group’s assets or
ownership interests, a bona fide prospective assignee of all or a portion of Cheniere’s interest in this Agreement, lender and its representatives, rating agencies or any other party in relation to project financing for the Project, provided
that Cheniere binds such persons or entity to the confidentiality obligations contained in this Paragraph 13.7 and to the term in Paragraph 13.11. 

  

	13.8	Definitions: The term “Confidential Information” shall mean one or both of Willbros’ Confidential Information and Cheniere’s Confidential Information, as
the context requires. The Party having the confidentiality obligations with respect to such Confidential Information shall be referred to as the “Receiving Party,” and the Party to whom such confidentiality obligations are owed shall be
referred to as the “Disclosing Party.” 

  

	13.9	 Exceptions: Notwithstanding Paragraphs 13.6 and 13.7, Confidential Information shall not include: (i) information which at the time of disclosure or
acquisition is in the public domain, or which after disclosure or acquisition becomes part of the public domain without violation of this Paragraph 13; (ii) information which at the time of disclosure or acquisition was already in the
possession of the Receiving Party or its employees or 

  

 A-39 

	 	 
agents and was not previously acquired from the Disclosing Party or any of its employees or agents directly or indirectly; (iii) information which the
Receiving Party can show was acquired by such entity after the time of disclosure or acquisition hereunder from a third party without any confidentiality commitment, if, to the best of Receiving Party’s or its employees’ or agent’s
knowledge, such third party did not acquire it, directly or indirectly, from the Disclosing Party or any of its employees or agents; (iv) information independently developed by the Receiving Party without benefit of the Confidential
Information, but specifically excluding the Work Product; and (v) information which is required by Applicable Law or other agencies in connection with the Project, to be disclosed; provided, however, that prior to such disclosure, the Receiving
Party gives reasonable notice to the Disclosing Party of the information required to be disclosed so that the Disclosing Party may attempt to seek an appropriate protective order or other remedy. 

  

	13.10 	Equitable Relief. The Parties acknowledge that in the event of a breach of any of the terms contained in this Paragraph 13, the Disclosing Party would suffer irreparable harm
for which remedies at law, including damages, would be inadequate, and that the Disclosing Party shall be entitled to seek equitable relief therefor by injunction, in addition to any and all rights and remedies available to it at law and in equity,
without the requirement of posting a bond. 

  

	13.11 	Term. The confidentiality obligations of this Paragraph 13 shall survive the expiration or termination of this Agreement for a period of five (5) years following the
expiration or earlier termination of this Agreement. 

  

	13.12 	Disclosure and Filings. Willbros acknowledges that Cheniere may be required from time to time to make filings in compliance with Applicable Law, including filing a copy of
this Agreement with the U.S. Securities and Exchange Commission. 

 14. DISPUTE RESOLUTION 
  

	14.1	Time Requirements for Claims: Should Willbros desire to seek an adjustment to the Guaranteed Maximum Price, the Project Schedule or any other modification to any other
obligation of Willbros under this Agreement for any circumstance that Willbros has reason to believe may give rise to a right to request the issuance of a Change Order, Willbros shall, with respect to each such circumstance:

  

	 	14.1.1 	 notify Cheniere in writing within fourteen (14) days of the date that Willbros knew or reasonably should have known of the first occurrence or beginning of
such circumstance. In such notice, Willbros shall state in detail all known and presumed facts upon which its claim is based, including the character, duration and extent of such circumstance, the date Willbros first knew of such circumstance, any
activities impacted by such circumstance, the cost and time consequences of such circumstance (including showing the impact of such circumstance, if any, on the critical path of the Work Plan) and any other details 

  

 A-40 

	 	 
or information that are expressly required under this Agreement. Willbros shall only be required to comply with the notice requirements of this Paragraph
14.1 once for continuing circumstances, provided the notice expressly states that the circumstance is continuing and includes Willbros’ best estimate of the time and cost consequences of such circumstance; and 

  

	 	14.1.2 	submit to Cheniere a request for a proposed Change Order as soon as reasonably practicable after giving Cheniere written notice but in no event later than fourteen (14) days
after the completion of each such circumstance, together with a written statement (i) detailing why Willbros believes that a Change Order should be issued, plus all documentation reasonably requested by or necessary for Cheniere to determine
the factors necessitating the possibility of a Change Order and all other information and details expressly required under this Agreement; and (ii) setting forth the effect, if any, which such proposed Change Order would have for the Work on
the Guaranteed Maximum Price and the Project Schedule. 

 The Parties acknowledge that Cheniere will be prejudiced if Willbros
fails to provide the notice required under this Paragraph 14.1, and agree that such requirement is an express condition precedent necessary to any right for an adjustment in the Guaranteed Maximum Price, the Project Schedule, any Work or any other
modification to any other obligation of Willbros under this Agreement. Oral notice, shortness of time, or Cheniere’s actual knowledge of a particular circumstance shall not waive, satisfy, discharge or otherwise excuse Willbros’ strict
compliance with this Paragraph 14.1. 
  

	14.2	Negotiation: In the event that any claim, dispute or controversy arising out of or relating to this Agreement (including the breach, termination or invalidity thereof, and
whether arising out of tort or contract) (“Dispute”) cannot be resolved informally within thirty (30) days after the Dispute arises, either Party may give written notice of the Dispute (“Dispute Notice”) to the other Party
requesting that a representative of Cheniere’s senior management and Willbros’ senior management meet in an attempt to resolve the Dispute. Each such management representative shall have full authority to resolve the Dispute and shall meet
at a mutually agreeable time and place within fourteen (14) days after receipt by the non-notifying Party of such Dispute Notice, and thereafter as often as they deem reasonably necessary to exchange relevant information and to attempt to
resolve the Dispute. In no event shall this Paragraph 14.2 be construed to limit either Party’s right to take any action under this Agreement, including Cheniere’s termination rights. The Parties agree that if any Dispute is not resolved
within thirty (30) days after receipt of the Dispute Notice given in this Paragraph 14.2, then either Party may by notice to the other Party refer the Dispute to be decided by final and binding arbitration in accordance with Paragraph 14.3.

  

	14.3	 Arbitration: Any arbitration held under this Agreement shall be held in Houston, Texas, unless otherwise agreed by the Parties, shall be administered by the
Dallas, Texas office of the American Arbitration Association (“AAA”) and shall, except as otherwise modified by this Paragraph 14.3, be governed by the AAA’s Construction Industry 

  

 A-41 

	 	 
Arbitration Rules and Mediation Procedures (including Procedures for Large, Complex Construction Disputes) (the “AAA Rules”). The number of
arbitrators required for the arbitration hearing shall be determined in accordance with the AAA Rules. The arbitrator(s) shall determine the rights and obligations of the Parties according to the substantive law of the state of Texas, excluding its
conflict of law principles, as would a court for the state of Texas; provided, however, the law applicable to the validity of the arbitration clause, the conduct of the arbitration, including resort to a court for provisional remedies, the
enforcement of any award and any other question of arbitration law or procedure shall be the Federal Arbitration Act, 9 U.S.C.A. § 2. Issues concerning the arbitrability of a matter in dispute shall be decided by a court with proper
jurisdiction. The Parties shall be entitled to engage in reasonable discovery, including the right to production of relevant and material documents by the opposing Party and the right to take depositions reasonably limited in number, time and place,
provided that in no event shall any Party be entitled to refuse to produce relevant and non-privileged documents or copies thereof requested by the other Party within the time limit set and to the extent required by order of the arbitrator(s). All
disputes regarding discovery shall be promptly resolved by the arbitrator(s). This agreement to arbitrate is binding upon the Parties, Willbros’ surety (if any) and the successors and permitted assigns of any of them. At Cheniere’s sole
option, any other person may be joined as an additional party to any arbitration conducted under this Paragraph 14.3, provided that the party to be joined is or may be liable to either Party in connection with all or any part of any Dispute between
the Parties. The arbitration award shall be final and binding, in writing, signed by all arbitrators, and shall state the reasons upon which the award thereof is based. The Parties agree that judgment on the arbitration award may be entered by any
court having jurisdiction thereof. 

  

	14.4	Continued Performance: Notwithstanding any Dispute, so long as Cheniere continues to pay Willbros undisputed amounts in accordance with this Agreement, it shall be the
responsibility of Willbros to continue to prosecute all of the Work diligently and in a good and workmanlike manner in conformity with this Agreement. Except to the extent provided in Paragraph 18, Willbros shall have no right to cease performance
hereunder or to permit the prosecution of the Work to be delayed. Cheniere shall, subject to its right to withhold or offset amounts pursuant to this Agreement, continue to pay Willbros undisputed amounts in accordance with this Agreement; provided,
however, in no event shall the occurrence of any negotiation or arbitration prevent or restrict Cheniere from exercising its rights under this Agreement, at law or in equity, including Cheniere’s right to terminate pursuant to Paragraphs 16 or
17. 

 15. SUSPENSION OF WORK 
  

	15.1	 Suspension of Work: Cheniere may at any time, whether or not for cause, suspend performance of the Work, or any part thereof, by a Change Order specifying
the Work to be suspended and the effective date of such suspension. Willbros shall cease performance of such suspended Work on the effective date of suspension, but shall continue to perform any unsuspended Work and shall take reasonable steps to
minimize 

  

 A-42 

	 	 
any costs associated with such suspension. During any such suspension, Willbros shall take all reasonably necessary actions to maintain and safeguard the
suspended Work in a manner as Cheniere may reasonably require. Except when such suspension ordered by Cheniere is the result of or due to the fault or negligence of Willbros or any Subcontractor or Vendor, Willbros shall be entitled to the
reasonable costs (including actual, but not unabsorbed, overhead, contingency, risk and reasonable profit) of such suspension incurred during the suspension period, including demobilization and remobilization costs and costs incurred for Willbros
Personnel and for Willbros Equipment, at the standby rates, if any, specified in the Letter Agreement, if necessary, along with appropriate supporting documentation to evidence such costs, and a time extension to the Preparation and Material Receipt
Commencement Date, the Construction Commencement Date or the Scheduled Mechanical Completion Date if and to the extent permitted under Paragraph 20.2. In no event shall Willbros be entitled to any additional profits or damages due to such
suspension. 

  

	15.2	Resumption of Work: Unless otherwise instructed by Cheniere, Willbros shall during any such suspension maintain its staff and labor on or near the Work Site and otherwise be
ready to proceed expeditiously with the Work upon receipt of Cheniere’s further instructions. Cheniere may, at any time, authorize resumption of all or any part of the suspended Work by giving notice to Willbros specifying the part of Work to
be resumed and the effective date of such resumption. Suspended Work shall be promptly resumed by Willbros after receipt of such notice. 

 16. TERMINATION AT CHENIERE’S CONVENIENCE 
  

	16.1	Cheniere’s Rights to Terminate for Convenience: Cheniere may, at any time and at its sole convenience, terminate the Agreement or any part of the Work by giving notice
to Willbros specifying the Work to be terminated and the effective date of termination. 

  

	16.2	Obligations upon Termination for Convenience: Should Cheniere issue a termination notice in accordance with Paragraph 16.1, Willbros shall stop performance of the Work
involved on the effective date of termination, unless Cheniere directs Willbros to complete portions of the Work in progress. Such termination shall be effective in the manner specified in the notice, and upon receipt of such notice, Willbros shall,
unless the notice directs otherwise, comply with the obligations set forth in Paragraph 19. Upon such termination, it is agreed that the obligations of this Agreement shall continue as to Work already performed. It is further agreed in the event of
such termination that the amounts due Willbros in full and complete settlement of this Agreement shall be the sum of the following: 

  

	 	16.2.1 	The reasonable value of the Work satisfactorily performed prior to termination (the basis of payment being based on the terms of this Agreement, less previous payments, if any, paid
to Willbros under this Agreement), plus 

  

 A-43 

	 	16.2.2 	Reasonable direct close-out costs, but in no event shall Willbros be entitled to receive any amount for unabsorbed overhead, contingency or anticipatory profit.

 Willbros shall submit all reasonable direct close-out costs to Cheniere for verification and audit within sixty
(60) days following the effective date of termination. 
 17. TERMINATION BY CHENIERE FOR CAUSE 
  

	17.1	Default by Willbros: Should Willbros at any time: (a) commit a material breach of the Agreement; (b) cause, by any action or omission, any material stoppage or
delay of or interference with the work of Cheniere or its other consultants or contractors; (c) fail to comply with Applicable Law or Applicable Codes and Standards; or (d) become insolvent, have a receiver appointed, make a general
assignment or filing for the benefit of its creditors or file for bankruptcy protection, in which such case of insolvency, receivership or assignment the cure provisions found below shall not apply; then, in any such event and without prejudice to
any other rights available under this Agreement, Cheniere may provide written notice to Willbros specifying the general nature of the default and demanding cure thereof. If, within seven (7) days after receipt of such notice Willbros has failed
to cure such default, or if the default cannot be cured with the exercise of reasonable diligence within such seven (7) days but Willbros fails to commence corrective action and cure such condition within an additional fourteen (14) days,
Cheniere may, at its option: (i) take such steps as are necessary to overcome the default or deficiency stated in its notice, in which case Willbros shall be liable to Cheniere for all related costs in connection therewith (including all
attorneys’ fees, consultant fees and litigation or arbitration expenses) which may be offset by Cheniere at its option; or (ii) terminate for default Willbros’ performance of all or part of the Work. 

  

	17.2	Additional Rights of Cheniere upon Default Termination: In the case of termination for default, Cheniere may, at its option, either itself or through others complete the Work
by whatever method Cheniere may deem expedient, including taking possession, for the purposes of completing the Work, of all Willbros Equipment and materials and/or taking assignment of any or all of Willbros subcontracts or purchase orders for the
Project. In the event of termination under this Paragraph 17, Willbros shall not be entitled to receive any further payment until the Work shall be fully completed and accepted by Cheniere, and Willbros shall be liable to Cheniere for all costs,
damages, losses and expenses (including all attorneys’ fees, consultant fees and litigation or arbitration expenses) incurred by Cheniere in completing the Work, either itself or through others, including all Liquidated Damages to the extent
payable pursuant to Paragraph 21 of this Agreement. 

  

	17.3	Conversion: If any termination for default by Cheniere pursuant to Paragraph 17.1 is found to be not in accordance with the provisions of this Agreement or is otherwise
deemed to be unenforceable, then such termination shall be deemed to be a termination for convenience as provided in Paragraph 16. 

  

 A-44 

 18. TERMINATION BY WILLBROS 
 Should Cheniere fail to pay Willbros undisputed invoiced amounts when due under this Agreement, Willbros may demand in writing that Cheniere comply with the payment terms of this Agreement. If, within forty-five
(45) days after Cheniere’s receipt of such a demand, Cheniere has not taken satisfactory steps to cure such failure, Willbros may, without prejudice to the exercise of any other rights or remedies which may be available to it, terminate
this Agreement by giving Cheniere written notice to that effect. Such termination hereunder by Willbros shall be effective on the date specified in Willbros’ termination notice. In the event of termination under this Paragraph 18, Willbros have
the rights (and Cheniere shall make the payments) provided for in Paragraph 16 in the event of a Cheniere termination for convenience. The right of Willbros to terminate this Agreement for cause shall be without prejudice to, and not in lieu of, any
other remedies available to Willbros under this Agreement. 
 19. WILLBROS’ OBLIGATIONS UPON SUSPENSION OR TERMINATION

  

	19.1	Willbros’ Obligations: If the Agreement or any portion of the Work is suspended or terminated as provided in Paragraphs 15, 16, 17, or 18 and if Cheniere so requests,
Willbros shall: 

  

	 	19.1.1 	immediately discontinue Work on the date and to the extent specified in the notice; 

  

	 	19.1.2 	place no further orders for subcontracts, materials, equipment, or any other items or services except as may be necessary for completion of such portion of the Work as is not
discontinued, thereafter execute only that portion of the Work not terminated (if any); 

  

	 	19.1.3 	inventory, maintain and turn over to Cheniere all Willbros Equipment or any other equipment or other items provided by Cheniere for performance of the terminated Work;

  

	 	19.1.4 	promptly make every reasonable effort to procure cancellation upon the best terms as are reasonably obtainable under the circumstances and which are satisfactory to Cheniere of any
or all subcontracts, purchase orders and rental agreements to the extent they relate to the performance of the Work that is discontinued unless Cheniere elects to take assignment of any such subcontracts, purchase orders and rental agreements
pursuant to Paragraph 19.2; 

  

	 	19.1.5 	cooperate with Cheniere in the transfer of Work Product, including Drawings, licenses and any other items or information and disposition of Work in progress so as to mitigate
damages; 

  

	 	19.1.6 	comply with other reasonable requests from Cheniere regarding the terminated Work; 

  

 A-45 

	 	19.1.7 	do whatever is necessary to preserve and protect Work in progress, to protect materials, equipment and supplies in transit or at the Work Site for the Project, to comply with any
Applicable Law and any Applicable Codes and Standards, and to minimize all costs to Cheniere and Willbros resulting from such suspension or termination; and 

  

	 	19.1.8 	perform all other obligations under Paragraph 17.2. 

  

	19.2	Assignment of Subcontracts and Other Agreements: If the Agreement or any portion of the Work is suspended or terminated as provided in Paragraphs 15, 16, 17, or 18, Cheniere
may, at its sole option, take assignment of any or all subcontracts, purchase orders and rental agreements. 

 20. FORCE
MAJEURE AND CHENIERE-CAUSED DELAY 
  

	20.1	Force Majeure: 

  

	 	20.1.1 	Willbros Relief: If the commencement, prosecution or completion of any Work is delayed by Force Majeure, then Willbros shall be entitled to an extension to the Scheduled
Mechanical Completion Date to the extent, if any, permitted under Paragraph 20.1.1.1 and an adjustment to the Guaranteed Maximum Price to the extent, if any, permitted under Paragraph 20.1.1.2, provided that Willbros complies with the notice and
Change Order request requirements in Paragraph 14.1 and the mitigation requirements in Paragraph 20.4. All time extensions to the Project Schedule and adjustments to the Guaranteed Maximum Price for such delays shall be by Change Order implemented
and documented as required under Paragraph 9. 

 20.1.1.1 Willbros shall be entitled to an extension to the Scheduled Mechanical
Completion Date for delay that meets the requirements of Paragraph 20.1.1 if and to the extent such delay affects the performance of any Work that is on the critical path of the Work Plan and causes Willbros to achieve Mechanical Completion beyond
the Scheduled Mechanical Completion Date, but only if Willbros is unable to proceed with other portions of the Work so as not to cause a delay in the Scheduled Mechanical Completion Date. 
 20.1.1.2 Willbros shall be entitled to an adjustment to the Guaranteed Maximum Price for any delay or prevention that meets the requirements of Paragraph
20.1.1, if such delay or prevention occurs for a continuous period of at least five (5) days in any thirty (30) day period. If Willbros is entitled to such adjustment to the Guaranteed Maximum Price, the adjustment to the Guaranteed
Maximum Price shall only include reimbursement for the standby time for Willbros’ employees and Willbros Equipment and other standby expenses which are incurred by Willbros after the expiration of such five (5) day period and which 

  

 A-46 

 
are caused by such Force Majeure and the effects thereof. Willbros shall take all reasonable measures, pursuant to Paragraph 20.4, to mitigate the standby
and other Force Majeure costs it incurs, and shall cooperate with Cheniere to help overcome such Force Majeure event. Reimbursement for such standby expenses and other Force Majeure costs shall be subject to an aggregate amount of One Million Five
Hundred Thousand Dollars (U.S.$ 1,500,000). 
  

	 	20.1.2 	Cheniere Relief. Subject to Paragraph 20.1.3, Cheniere’s obligations under this Agreement shall be suspended to the extent that performance of such obligations is
delayed by Force Majeure, but only if Cheniere notifies Willbros of the existence of such event of Force Majeure within fourteen (14) days after its occurrence and complies with the mitigation requirements in Paragraph 20.4.

  

	 	20.1.3 	Payment Obligations: No obligation of a Party to pay moneys under or pursuant to this Agreement shall be excused by reason of Force Majeure. 

  

	20.2	Cheniere-Caused Delay: Should Cheniere or any person or entity acting on behalf of or under the control of Cheniere (including to any third party contractors working in
connection with the Project) delay the commencement, prosecution or completion of the Work, and if such delay is not in any way attributable to Willbros or its Subcontractors or Vendors but is caused by (a) Cheniere’s or such person or
entity’s active interference in the Work, (b) Cheniere’s ordering a Change in the Work (provided that a Change Order has been issued in accordance with Paragraph 9), or (c) Cheniere’s or such person or entity’s failure
to perform its material obligations pursuant to this Agreement, including the failure to provide access to the Work Site in accordance with Paragraph 5.2, then Willbros shall be entitled to an adjustment in the Guaranteed Maximum Price and an
extension to the Scheduled Mechanical Completion Date if (i) such delay affects the performance of any Work that is on the critical path of the Work Plan, (ii) such delay causes Willbros to complete the Work beyond the Scheduled Mechanical
Completion Date, (iii) Willbros is unable to proceed with other portions of the Work so as not to cause a delay in the Scheduled Mechanical Completion Date and (iv) Willbros complies with the notice and Change Order request requirements in
Paragraph 14.1 and the mitigation requirements of Paragraph 20.4. Any adjustment to the Guaranteed Maximum Price shall be for reasonable, additional direct costs incurred by Willbros for such delay meeting the requirements of this Paragraph 20.2,
and any adjustments to the Guaranteed Maximum Price or the Project Schedule shall be recorded in a Change Order. 

  

	20.3	Delay: For the purposes of Paragraph 20, the term “delay” shall include hindrances, disruptions or obstructions, or any other similar term in the industry and the
resulting impact from such hindrances, disruptions or obstructions, including inefficiency, impact, or lost production. 

  

	20.4	Obligation to Mitigate Delay: At all times in the event of a delay, the Parties shall take reasonable actions to mitigate such delay. 

  

 A-47 

 21. LIQUIDATED DAMAGES 
  

	21.1	Liquidated Damages: If Mechanical Completion occurs after the Scheduled Mechanical Completion Date, Willbros shall pay Cheniere in amounts according to the following schedule
for each day of delay until Mechanical Completion occurs (“Liquidated Damages”): 

  

	 	21.1.1 	one (1) through thirty (30) days after the Scheduled Mechanical Completion Date: Zero U.S. Dollars ($0) per day; and 

  

	 	21.1.2 	thirty-one (31) days through sixty (60) days inclusive after the Scheduled Mechanical Completion Date at Five Thousand Dollars ($5,000) per day; 

 

	 	21.1.3 	sixty-one (61) days through ninety (90) days inclusive after the Scheduled Mechanical Completion Date at Seven Thousand Dollars ($7,000) per day; and

  

	 	21.1.4 	ninety-one (91) days and thereafter until Mechanical Completion is achieved at Ten Thousand Dollars ($10,000) per day. 

 Provided, however, in no event shall such Liquidated Damages exceed the total sum of Five Hundred Sixty Thousand Dollars ($560,000), provided that such
limitation of liability shall not be construed to limit Willbros’ other obligations or liabilities under this Agreement (including its obligations (i) to complete the Work for the compensation provided under this Agreement, (ii) to
perform all Work required to achieve Start-up and Project Completion, and (iii) with respect to Warranties), nor shall such limitation of liability apply in the event of Willbros’ willful misconduct (including the willful refusal to
perform the Work, willful delay in performing the Work or abandonment of the Work) or gross negligence. 
  

	21.2	Liquidated Damages Not a Penalty: It is expressly agreed that Liquidated Damages payable under this Agreement do not constitute a penalty and that the Parties, having
negotiated in good faith for such specific Liquidated Damages and having agreed that the amount of such Liquidated Damages is reasonable in light of the anticipated harm caused by the breach related thereto and the difficulties of proof of loss and
inconvenience or nonfeasibility of obtaining any adequate remedy, are estopped from contesting the validity or enforceability of such Liquidated Damages. In the event any Liquidated Damages are held to be unenforceable due to the urging by or on
behalf of any member of the Willbros Group, Willbros specifically agrees to pay Cheniere all actual damages incurred by Cheniere in connection with such breach, including any and all consequential damages (such as loss of profits and revenues,
business interruption, loss of opportunity and use) and all costs incurred by Cheniere in proving the same. 

  

	21.3	 Payment of Liquidated Damages: With respect to any Liquidated Damages that accrue, Cheniere, at its sole discretion, may either (i) invoice Willbros for
such owed Liquidated Damages, and within thirty (30) days of Willbros’ receipt of such invoice, Willbros shall 

  

 A-48 

	 	 
pay Cheniere Liquidated Damages, or (ii) withhold from Willbros amounts that are otherwise due and payable to Willbros in the amount of such Liquidated
Damages. In addition, with respect to the achievement of Mechanical Completion, Willbros shall pay Cheniere all Liquidated Damages, if any, owed under this Agreement as a condition precedent to achieving such Mechanical Completion.

 22. PUBLICITY RELEASES 
 Should Willbros or any of its Subcontractors or Vendors desire to publish or release any publicity or public relations materials of any kind relating to the Agreement specifically or the Project generally, Willbros
shall first submit such material to Cheniere for review. Willbros shall not publish or release any such material without Cheniere’s prior consent, such consent not to be unreasonably withheld. 
 23. GOVERNING LAW 
 It is understood that the
Agreement is governed by the laws of the State of Texas except to the extent its conflict of law principles would refer to the law of another jurisdiction, the Parties acknowledge that the laws of Louisiana govern the rights and obligations of the
Parties as to the validity and enforcement of mechanics’ and materialmen’s liens. Only to the extent that either Party may seek relief of the courts pursuant to this Agreement, Cheniere and Willbros each hereby submit to the exclusive
jurisdiction of the federal and state courts located in Houston, Texas, and agree that service of process may be affected upon them by delivery to the addresses given in the Signature Document. 
 24. GENERAL PROVISIONS 
  

	24.1	Assignment: The Agreement shall be binding upon and inure to the benefit of the successors and assigns of the Parties to the Agreement. The Agreement may neither be assigned
nor transferred by either Party, either in whole or in part, without first obtaining the written consent of the other Party, and any attempt to make such an assignment shall be void; provided, however, that Willbros reserves the right to pledge or
assign its rights to payment under this Agreement in accordance with its agreements with its lenders; provided further, however, that in no event shall a pledge or assignment of rights to payment by Willbros create or impose any additional
obligation on Cheniere or otherwise void or preclude any rights or privileges of Cheniere or any member of the Cheniere Group under this Agreement. Notwithstanding the foregoing, Cheniere may freely assign this Agreement, in whole or in part,
without Willbros’ consent to any affiliate or successor of Cheniere or to any third party making a loan to Cheniere or purchasing the Project. 

  

	24.2	 Ownership and Transfer: Cheniere represents that, once title is transferred as provided in this Agreement, it is the sole owner of the Project. Cheniere
further agrees that any future transferee of any interest in the Project will be subject to the releases and limitations of liability set forth in the Agreement such that the total aggregate liability of Willbros to 

  

 A-49 

	 	 
Cheniere and such recipients shall not exceed, relative to any transferee, the limits of liability set forth in the Agreement. 

 

	24.3	No Waiver: No benefit or right accruing to either Party under the Agreement shall be waived unless the waiver is reduced to writing and signed by both Parties. The waiver, in
one instance, of any act, condition or requirement stipulated in the Agreement shall not constitute a continuing waiver or a waiver of any act, condition or requirement or a waiver of the same act, condition or requirement in other instances, unless
specifically so stated. 

  

	24.4	Status of Willbros: Willbros shall be and always remain an independent contractor with respect to the Work performed under the Agreement. Neither Willbros, its
Subcontractors, its Vendors, nor the Willbros Personnel shall be deemed to be the servants, agents or employees of Cheniere. Willbros shall exercise control, management and direction over the details and means of performing the Work and shall be
subject to the directions of Cheniere only with respect to the scope and general results required. 

  

	24.5	Third Party Beneficiaries: This Agreement shall not be deemed for the benefit of any third party nor shall it give any person not a Party to the Agreement any right to
enforce its provisions. 

  

	24.6	Survival: The provisions of Paragraphs 9.6, 10, 11, 12, 13, 14, 16, 17, 18, 19, 20 and 23 shall survive the final settlement or termination of the Agreement, for whatever
reason. 

  

	24.7	Severability: Any term or provision of the Agreement judicially determined to be invalid or unenforceable to any entity or circumstance shall be deemed, to such
extent, invalid or unenforceable, but the remainder of the Agreement shall remain unaffected and be enforceable according to its terms. 

  

	24.8	Headings: The headings hereof shall not be considered in interpreting the text of the Agreement and are inserted for convenience of reference only. 

 

	24.9	Further Assurances: Each Party shall perform the acts and execute and deliver the documents and give reasonable assurances necessary to give effect to the provisions of the
Agreement; provided that Cheniere shall only be required to give any such assurances upon a material change in the creditworthiness of Cheniere or upon any other significant adverse change to Cheniere. Any assurances required under this Paragraph
24.9 shall not involve the assumption of obligations greater than those provided for in this Agreement. 

  

	24.10 	 Entire Agreement: This Agreement supersedes all previous quotations, proposals, letter agreements, contracts, agreements, understandings and correspondence
between the Parties regarding the Work, and constitutes the entire agreement between the Parties concerning the Work. Notwithstanding the foregoing, the Parties acknowledge that the Letter Agreement shall be simultaneously executed with this
Agreement. No promise, agreement, representation or modification to the Agreement shall be of any force or effect 

  

 A-50 

	 	 
between the Parties unless expressly set forth or provided for in the Agreement, a Change Order or an Amendment. 

  

	24.11 	Interpretation: The word “include” or “including” shall mean including without limitation. The words “hereof”, “herein”,
“hereunder” and “hereto” refer to the Agreement as a whole, including the Schedules, and not to any particular provision of the Agreement unless expressly indicated. Unless the context clearly requires otherwise, references to
the plural include the singular and the singular the plural. References to “days” or a “day” shall mean a calendar day, unless otherwise stated. Where a Party’s approval or acceptance is required, such approval or acceptance
shall not be unreasonably delayed. 

  

	24.12 	Lender Requirements: In addition to other assurances provided in this Agreement, Willbros acknowledges that Cheniere has obtained or may obtain financing, which may be
project financing, associated with the Work, and Willbros agrees to cooperate with Cheniere and Cheniere’s lenders in connection with such Project financing, including entering into direct agreements with such lenders, as reasonably required by
such lenders, covering matters that are customary in project financings of this type such as lender assignment or security rights with respect to this Agreement, consent agreements, opinions of counsel, direct notices to lender and lender’s
independent engineer, step-in/step-out rights, access by lender’s representative, including lender’s independent engineer, and other matters applicable to such Project financing. Willbros shall cooperate with any independent engineer
retained by Cheniere’s lender(s) in the conduct of such independent engineers’ duties in relation to the Project, including the Work. No review, approval or disapproval by any independent engineer shall serve to reduce or limit the
liability of Willbros to Cheniere under this Agreement. 

  

	24.13	Counterparts: This Agreement may be signed in any number of counterparts and each counterpart shall represent a fully executed original as if signed by each of the Parties.
Facsimile signatures shall be deemed as effective as original signatures. 

  

	24.14	Priority. The documents that form this Agreement are listed below in order of priority, with the document having the highest priority listed first and the one with the lowest
priority listed last. Subject to Paragraph 1.6 under the definition of Applicable Codes and Standards regarding conflicts or inconsistencies between any Applicable Codes and Standards, in the event of any conflict or inconsistency between a
provision in one document and a provision in another document, the document with the higher priority shall control. In the event of a conflict or inconsistency between provisions contained within the same document, then the provision that requires
the highest standard of performance on the part of Willbros shall control. This Agreement is composed of the following documents, which are listed in priority: 

  

	 	24.14.1 	Change Orders or Amendments to this Agreement; 

  

	 	24.14.2 	The Signature Document; 

  

 A-51 

	 	24.14.3 	This Schedule “A”; and 

  

	 	24.14.4 	All other Schedules and Attachments to this Agreement. 

 END OF SCHEDULE “A”  
  

 A-52 

 ATTACHMENT I 
 WILLBROS’ PARENT GUARANTEE 
 This GUARANTEE (this “Guarantee”) effective
February 01, 2006, is made by Willbros USA, Inc. organized under the laws of the State of Delaware (“Guarantor”), in favor of Cheniere Sabine Pass Pipeline Company, a company organized under the laws of the State of
Delaware (“Owner,” and, together with Guarantor, each a “Party” and, collectively, the “Parties”). Capitalized terms used, but not otherwise defined, herein shall have the
respective meanings ascribed to such terms in the Agreement (as defined below). 
 RECITALS 
 WHEREAS, Owner has agreed to enter into the Agreement for the Engineering, Procurement and Construction of the 42-inch Sabine Pass Pipeline dated
February 01, 2006, with Willbros Engineers, Inc. (“Willbros”) for the engineering, procurement, construction, commissioning, start-up and testing of the 42-inch Sabine Pass Pipeline Project (the
“Project”) located in Cameron Parish, Louisiana and a letter agreement dated February 01, 2006, with Willbros (collectively, the “Agreement”), which are hereby incorporated by reference in this
Guarantee and made a part hereof; and 
 WHEREAS, Willbros is a subsidiary of Guarantor; and 
 WHEREAS, it is a condition to Owner and Willbros’ entering into the Agreement that Guarantor execute and deliver this Guarantee. 

NOW THEREFORE, in consideration of the promises and other good and valuable consideration, the receipt and sufficiency of which are hereby
acknowledged, the Parties hereby agree as follows: 
 1. Guarantee. 
 (a) On the terms and subject to the conditions contained herein, Guarantor hereby unconditionally and irrevocably guarantees, to and for the benefit of
Owner, the full and punctual performance and payment, as and when each such payment or performance becomes due (whether at the stated due date, by acceleration or otherwise), by or on behalf of Willbros of any and all obligations or amounts owed by
Willbros to Owner in connection with and to the extent provided for in the Agreement (the “Guaranteed Obligations”). The Guaranteed Obligations of Guarantor hereunder are direct and primary obligations. 
 (b) This Guarantee is an unconditional, present, and continuing guarantee of performance and payment, and not of collection, is in no way conditioned or
contingent upon any attempt to collect from or enforce performance or payment by Willbros or upon any other event, contingency or circumstance whatsoever, and shall remain in full force and effect and be binding upon and against Guarantor and its
successors and permitted assigns (and shall inure to the benefit of Owner and its successors, endorsees, transferees, and permitted assigns), without 

  

 A-53 

 
regard to the validity or enforceability of the Agreement. If, for any reason, Willbros shall fail or be unable duly, punctually, and fully to perform or
pay, as and when such performance or payment is due, any of the Guaranteed Obligations, Guarantor shall promptly perform or pay, or cause to be performed or paid, such Guaranteed Obligations. 
 (c) Guarantor agrees that any judgment from any litigation (or any award resulting from any arbitration, if Owner and Willbros should agree to arbitrate)
between Willbros and Owner under the Agreement (whether in contested litigation or arbitration, by default or otherwise) shall be conclusive and binding on the Parties for the purposes of determining Guarantor’s obligations under the Guarantee.

 (d) Guarantor further agrees to pay to Owner any and all costs, expenses (including, without limitation, all reasonable fees and
disbursements of counsel), and damages which may be paid or incurred by Owner in enforcing any rights with respect to this Guarantee, including, without limitation, collecting against Guarantor under this Guarantee. 
 2. Obligations Unconditional, Continuing; Etc. 
 Guarantor agrees that the obligations of Guarantor set forth in this Guarantee shall be direct obligations of Guarantor, and such obligations shall be irrevocable and unconditional, shall not be subject to any counterclaim, set-off,
deduction, diminution, abatement, recoupment, suspension, deferment, reduction or defense (other than full and strict compliance with its obligations hereunder) based upon any claim Guarantor or any other person may have against Owner or any other
person and shall remain in full force and effect without regard to and shall not be released, discharged or in any way affected or impaired by, any circumstance or condition whatsoever (other than full and strict compliance by Guarantor with its
obligations hereunder) (whether or not Guarantor shall have any knowledge or notice thereof), including, without limitation: (i) any amendment or modification of or supplement to or other change in the Agreement or any other document,
including, without limitation, any change order, renewal, extension, acceleration or other changes to payment terms thereunder; (ii) any failure, omission or delay on the part of Owner or any other person to confirm or comply with any term of
the Agreement, (iii) any waiver, consent, extension, indulgence, compromise, release or other action or inaction under or in respect of the Agreement or any other document or any obligation or liability of Owner or any other person, or any
exercise or non-exercise of any right, remedy, power, or privilege under or in respect of any such instrument or agreement or any such obligation or liability, other than as expressly set forth in writing executed by Owner and Guarantor;
(iv) any bankruptcy, insolvency, reorganization, arrangement, readjustment, liquidation, or similar proceeding with respect to Owner, Willbros or any other person or any of their respective properties, or any action taken by any trustee or
receiver or by any court in any such proceeding; (v) any discharge, termination, cancellation, invalidity or unenforceability, in whole or in part, of the Agreement or any other document or any term or provision thereof; (vi) any merger or
consolidation of Guarantor or Willbros into or with any other person or any sale, lease, or transfer of all or any of the assets of Guarantor or Willbros; (vii) any change in the ownership of Guarantor or Willbros; (viii) any winding up or
dissolution of Willbros; or (ix) to the extent permitted under Applicable Law, any other occurrence or circumstance whatsoever, whether similar or dissimilar to the foregoing, which might otherwise constitute a legal or 

  

 A-54 

 
equitable defense or discharge of the liabilities of guarantor or surety or which might otherwise limit recourse against Guarantor. Guarantor reserves the
right to (a) set-off against any payment that has become due and payable by the Owner to Willbros under the Agreement and (b) assert defenses which Willbros may have under or with respect to the Agreement to performance of any Guaranteed
Obligations other than defenses arising from the bankruptcy or insolvency of Willbros or Willbros’ failure to have the authority to (x) execute or deliver the Agreement or (y) perform its obligations under the Agreement. The
Guaranteed Obligations constitute the full recourse obligations of Guarantor enforceable against it to the full extent of all its assets and properties. Without limiting the generality of the foregoing, Guarantor agrees that repeated and
successive demands may be made and recoveries may be had hereunder as and when, from time to time, Willbros shall fail to perform obligations or pay amounts owed by Willbros under the Agreement and that notwithstanding the recovery hereunder for or
in respect of any given failure to so comply by Willbros under the Agreement, this Guarantee shall remain in full force and effect and shall apply to each and every subsequent such failure. 
 3. Reinstatement. Guarantor agrees that this Guarantee shall be automatically reinstated with respect to any payment made by or on behalf of Willbros
pursuant to the Agreement if and to the extent that such payment is rescinded or must be otherwise restored, whether as a result of any proceedings in bankruptcy or reorganization or otherwise. 
 4. Waiver of Demands, Notices; Etc. Guarantor hereby unconditionally waives, to the extent permitted by Applicable Law: (i) notice of any of the
matters referred to in Paragraph 2 hereof; (ii) all notices which may be required by Applicable Law, or otherwise, now or hereafter in effect, to preserve any rights against Guarantor hereunder, including, without limitation, any demand, proof,
or notice of non-payment or non-performance of any Guaranteed Obligation; (iii) any right to the enforcement, assertion, or exercise of any right, remedy, power, or privilege under or in respect of the Agreement; (iv) notice of acceptance
of this Guarantee, demand, protest, presentment, notice of failure of performance or payment, and any requirement of diligence; (v) any requirement to exhaust any remedies or to mitigate any damages resulting from failure of performance or
payment by Willbros under the Agreement or by any other person under the terms of the Agreement; and (vi) any other circumstance whatsoever which might otherwise constitute a legal or equitable discharge, release, or defense of a guarantor or
surety, or which might otherwise limit recourse against Guarantor. 
 5. No Subrogation. Notwithstanding any performance, payment or payments
made by Guarantor hereunder (or any set-off or application of funds of Guarantor by Owner), Guarantor shall not be entitled to be subrogated to any of the rights of Willbros or of any rights of Owner hereunder, or any collateral, security, or
guarantee or right of set-off held by Owner, for the performance or payment of the obligations guaranteed hereunder, nor shall Guarantor seek or be entitled to assert or enforce any right of contribution, reimbursement, indemnity or any other right
to payment from Willbros as a result of Guarantor’s performance of its obligations pursuant to this Guarantee until all Guaranteed Obligations are performed or paid in full. If any amount shall be paid to Guarantor on account of such
subrogation, contribution, reimbursement or indemnity rights at any time when all of the Guaranteed Obligations and all amounts owing hereunder shall not have been performed and paid in full, such amount shall be held by Guarantor in trust for
Owner, segregated from other funds of Guarantor, and shall, forthwith 

  

 A-55 

 
upon receipt by Guarantor, be turned over to Owner in the exact form received by Guarantor (duly endorsed by Guarantor to Owner, if required), to be applied
against the Guaranteed Obligations, whether or not matured, in such order as Owner may determine. 
 6. Representations and Warranties.
Guarantor represents and warrants that: 
 (a) it is a corporation duly organized and validly existing under the laws of the State of
Delaware and has the corporate power and authority to execute, deliver and carry out the terms and provisions of the Guarantee; 
 (b) the
execution, delivery and performance of this Guarantee will not conflict with, violate or breach the terms of any agreement of Guarantor; 
 (c) no authorization, approval, consent or order of, or registration or filing with, any court or other governmental body having jurisdiction over Guarantor is required on the part of Guarantor for the execution and delivery of this
Guarantee; and 
 (d) this Guarantee, when executed and delivered, will constitute a valid and legally binding agreement of Guarantor, except
as the enforceability of this Guarantee may be limited by the effect of any applicable bankruptcy, insolvency, reorganization, moratorium or similar laws affecting creditors’ rights generally and by general principles of equity as they apply to
the Guarantor. 
 7. Miscellaneous. 
 (a) This Guarantee shall inure to the benefit of and be binding upon the Parties hereto and their respective successors and permitted assigns. Guarantor may not assign or transfer this Guarantee or any rights or obligations hereunder
without Owner’s prior written consent. Owner may assign this Guarantee, in whole or part, to any of its affiliates or co-venturers or to any person jointly controlled by Owner and any co-venturers. Furthermore, Owner may assign, pledge
and/or grant a security interest in this Guarantee to any lender without Guarantor’s consent. Except as otherwise provided in this Paragraph 7, nothing herein, express or implied, is intended or shall be construed to confer upon or to give to
any person other than the Parties hereto any rights, remedies, or other benefits. 
 (b) This Guarantee shall be governed by, and construed
in accordance with, the laws of the state of Texas, without giving effect to the principles thereof relating to conflicts of law. 
 (c) The
Parties agree that any claim, dispute, controversy, difference, disagreement, or grievance (of any and every kind or type, whether based on contract, tort, statute, regulation or otherwise) arising out of, connected with, or relating in any way to
this Guarantee (including, without limitation, the construction, validity, interpretation, termination, enforceability or breach of this Guarantee, the relationship of the Parties established by this Guarantee, or any dispute over arbitrability or
jurisdiction) (“Dispute”) shall be decided by final and binding arbitration. Any arbitration held under this Guarantee shall be held in Houston, Texas, unless otherwise agreed by the Parties, shall be administered by the
Dallas, Texas office of the American Arbitration Association (“AAA”) and shall, except as otherwise modified by this Paragraph 7(c), 

  

 A-56 

 
be governed by the AAA’s Construction Industry Arbitration Rules and Mediation Procedures (including Procedures for Large, Complex Construction
Disputes) (the “AAA Rules”). The number of arbitrators required for the arbitration hearing shall be determined in accordance with the AAA Rules. The arbitrator(s) shall determine the rights and obligations of the Parties
according to the substantive law of the state of Texas, excluding its conflict of law principles, as would a court for the state of Texas; provided, however, the law applicable to the validity of the arbitration clause, the conduct of the
arbitration, including resort to a court for provisional remedies, the enforcement of any award and any other question of arbitration law or procedure shall be the Federal Arbitration Act, 9 U.S.C.A. § 2. Issues concerning the arbitrability of
a matter in dispute shall be decided by a court with proper jurisdiction. The Parties shall be entitled to engage in reasonable discovery, including the right to production of relevant and material documents by the opposing Party and the right to
take depositions reasonably limited in number, time and place, provided that in no event shall any Party be entitled to refuse to produce relevant and non-privileged documents or copies thereof requested by the other Party within the time limit set
and to the extent required by order of the arbitrator(s). All disputes regarding discovery shall be promptly resolved by the arbitrator(s). This agreement to arbitrate is binding upon the Parties and the successors and permitted assigns of any of
them. At Owner’s sole option, any other person may be joined as an additional party to any arbitration conducted under this Paragraph 7(c), provided that the party to be joined is or may be liable to either Party in connection with all or any
part of any Dispute between the Parties. The arbitration award shall be final and binding, in writing, signed by all arbitrators, and shall state the reasons upon which the award thereof is based. The Parties agree that judgment on the arbitration
award may be entered by any court having jurisdiction thereof. 
 (d) No modification or amendment of this Guarantee shall be of any force or
effect unless made in writing, signed by the Parties hereto, and specifying with particularity the nature and extent of such modification or amendment. This Guarantee constitutes the entire and only understanding and agreement among the Parties
hereto with respect to the subject matter hereof and cancels and supersedes any prior negotiations, proposals, representations, understandings, commitments, communications, or agreements, whether oral or written, with respect to the subject matter
hereof. 
 (e) All notices, requests and communications to a Party hereunder shall be in writing (including telecopy and/or fax or similar
writing) and shall be sent: 
 If to Owner: 
 Graham A. McArthur 
 Vice President and Treasurer 
 Cheniere Sabine Pass Pipeline 
 717 Texas
Avenue, Suite 3100 
 Houston, Texas 77002 
 Telephone: (713) 659-1361 
 Fax: (713) 659-5459 
  

 A-57 

 If to Guarantor: 
 Gay S. Mayeux 
 Vice President and Assistant Treasurer 
 Willbros USA, Inc. 
 4400 Post Oak Parkway

 Suite 1000 
 Houston, Texas
77027 
 Telephone: (713) 403-8147 
 Fax: (713) 403-8017 
 or to such other address or telecopy number and with such other copies, as such Party may hereafter reasonably specify
by notice to the other Parties. Each such notice, request or communication shall be effective upon receipt, provided that if the day of receipt is not a business day then it shall be deemed to have been received on the next succeeding business day.

 (f) The headings of the several provisions of this Guarantee are inserted for convenience only and shall not in any way affect the meaning
or construction of any provision of this Guarantee. 
 (g) No forbearance or delay by Owner in asserting rights against Willbros shall affect
or impair in any way Guarantor’s obligations hereunder or the rights of Owner hereunder. 
 (h) In addition to other assurances provided
in this Guarantee, Guarantor acknowledges that Owner has obtained or may obtain project financing associated with the Project and Guarantor agrees to cooperate with Owner and its lenders in connection with such project financing, including, but not
limited to, entering into direct agreements with lenders, as required by such lenders, covering matters that are customary in project financings of this type such as lender assignment or security rights with respect to this Guarantee, consent
agreements, opinions of counsel, direct notices to lender and lender’s independent engineer, step-in/step-out rights, access by lenders’ representative, including lender’s independent engineer, and other matters applicable to such
project financing. 
 (i) This Guarantee may be executed in any number of separate counterparts and all of said counterparts taken together
shall be deemed to constitute one and the same instrument. 
 IN WITNESS WHEREOF, the undersigned have duly executed this Guarantee as
of the date first above written. 
  

			
	WILLBROS USA, INC.
		
	By:	 	  
	Name:	 	  
	Title:	 	  

  

 A-58 

			
	CHENIERE SABINE PASS PIPELINE COMPANY
		
	By:	 	  
	Name:	 	  
	Title:	 	  

  

 A-59 

 ATTACHMENT II - 1 
 PAYMENT BOND 
 Bond No.______________________________ 
 KNOW ALL MEN BY THESE PRESENTS, that ____________________________ (hereinafter “Principal”) and _______________________________________, incorporated in
the state of ________________ and duly authorized to do business in Louisiana, (hereinafter “Surety”), are held and firmly bound unto Cheniere Sabine Pass Pipeline Company (hereinafter “Obligee”), and its representatives,
successors and assigns, in the sum of _______________________________ Dollars ($___________) for the payment of which sum well and truly to be made the said Principal and Surety bind themselves, and their respective heirs, administrators, executors,
successors and assigns jointly and severally, firmly by these presents. 
 WHEREAS, Principal has been awarded a contract with Obligee for the project
known as the 42-inch Sabine Pass Pipeline Project in Cameron Parish, Louisiana (hereinafter called the “Contract”) and which Contract is hereby referred to and incorporated by express reference as if fully set forth herein. 
 NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION IS SUCH, that if the Principal shall promptly make payment in full to all persons or entities supplying labor,
material, services, utilities and equipment, or any other things in the prosecution of the work provided for in said Contract, and any and all modifications of said Contract that may hereafter be made, and shall indemnify and save harmless said
Obligee of and from any and all loss, damage, and expense, including costs and attorneys’ fees, which the said Obligee may sustain by reason of Principal’s failure to do so, then this obligation shall be null and void; otherwise it shall
remain in full force and effect. 
 The Surety agrees that no change, extension of time, alteration, addition, omission, waiver, or other modification of the
terms of either the Contract or in the work to be performed, or in the specifications, or in the plans, or in the contract documents, or any forbearance on the part of either the Obligee or Principal to the other, shall in any way affect its
obligation on this Bond, and Surety does hereby waive notice of any such changes, extensions of time, alterations, additions, omissions, waivers, or other modifications. 
 The Principal and the Surety agree that this Bond shall inure to the benefit of all persons or entities as supplying labor, material, services, utilities and equipment, or any other things in the prosecution of the
work provided for in said Contract, as well as to the Obligee, and that any of such persons or entities may maintain independent actions upon this Bond in the name of the person or entities bringing any such action. 
 The parties executing this Bond on behalf of Principal and Surety represent and warrant that they are duly authorized to bind the Principal and Surety respectively.

  

 A-60 

 IN WITNESS WHEREOF, the above bounden parties have executed this instrument under their several seals this _________ day
of _________________, 200__ the name and corporate seal of each corporate seal of each corporate party being hereto affixed and these presents duly signed by its undersigned representative, pursuant to authority of its governing body. 
  

			
	PRINCIPAL:
	
	  
		
	By:	 	  
	Title:	 	  
	  
	  
	  
	(Principal’s Address)

  

	
	 Witness

	
	   
	 Or Secretary’s Attest

	 [SEAL]

  

			
	SURETY:
	
	  
		
	By:	 	  
	Title:	 	  
	  
	  
	  
	(Surety’s Address)

  

	
	 Witness.

	
	   
	 Or Secretary’s Attest

	 [SEAL]

  

	
	[Attach Power of Attorney executed by attorney-in-fact on behalf of Surety]

  

 A-61 

 ATTACHMENT II - 2 
 DUAL OBLIGEE RIDER FOR PAYMENT BOND 
 This Rider is to be attached to and forms a part of Payment
Bond No. _____________________ issued by ____________________________ (hereinafter referred to as “Surety”), as Surety, on the ______ day of ___________________, 20__ (“Payment Bond”). 
 WHEREAS, on or about the ____ day of __________, 200_, ________________________ (hereinafter called the “Principal”), entered into a written
agreement with              (hereinafter called the “Primary Obligee”) for the construction of _____________________ (hereinafter called the “Contract”); and

 WHEREAS, the Principal and the Surety executed and delivered to said Primary Obligee the Performance Bond No. _______ (“Performance
Bond”) in connection with the Contract; and 
 WHEREAS, the Primary Obligee has requested the Principal and the Surety to execute and
deliver this Dual Obligee Rider for Payment Bond and the Principal and the Surety have agreed to do so. 
 NOW, THEREFORE, the undersigned
hereby agree and stipulate that Cheniere Sabine Pass Pipeline Company shall be a named obligee (hereinafter referred to as “Additional Obligee”) to the Payment Bond, subject to the conditions set forth below: 
 1. In the event of a material default in payment by the Primary Obligee to the Principal under the terms of the Contract, the right of the Additional
Obligee to recover hereunder shall be subject to the condition that the Additional Obligee remedies said material payment default and thereafter continues to make payment to the Principal as required under the terms of the Contract. 
 2. The aggregate liability of the Surety under the Payment Bond, to any or all of the obligees (Primary and Additional Obligees), as their interests may
appear, is limited to the total penal sum of the Payment Bond. 
 Signed, sealed and dated this ______ day of _____________________, 20__.

  

			
	PRINCIPAL:
	
	  
		
	By:	 	  
	Title:	 	  
	  
	  
	  
	(Principal’s Address)

  

 A-62 

	
	 Witness

	
	   
	 Or Secretary’s Attest

	 [SEAL]

  

			
	SURETY:
	
	  
		
	By:	 	  
	Title:	 	  
	  
	  
	  
	(Surety’s Address)

  

	
	 Witness.

	
	   
	 Or Secretary’s Attest

	 [SEAL]

  

	
	[Attach Power of Attorney executed by attorney-in-fact on behalf of Surety]

  

 A-63 

 ATTACHMENT II - 3 
 PERFORMANCE BOND 
 Bond No.________________________________ 
 KNOW ALL MEN BY THESE PRESENTS, that ____________________________ (hereinafter “Principal”) and ____________________________________, incorporated in
the state of and duly authorized to do business in Louisiana (hereinafter “Surety”), are held and firmly bound unto Cheniere Sabine Pass Pipeline Company (hereinafter “Obligee”), and its representatives, successors and assigns,
in the sum of __________ Dollars ($___________) for the payment of which sum well and truly to be made the said Principal and Surety bind themselves, and their respective heirs, administrators, executors, successors and assigns jointly and
severally, firmly by these presents. 
 WHEREAS, Principal has been awarded a contract with Obligee for the project known as the 42-inch Sabine Pass
Pipeline Project in Cameron Parish, Louisiana (hereinafter called the “Contract”) and which Contract is hereby referred to and incorporated by express reference as if fully set forth herein. 
 NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION IS SUCH, that if the above bounden Principal shall well and truly perform all the work, undertakings, covenants,
terms, conditions, and agreements of said Contract within the time provided therein and any extensions thereof that may be granted by Obligee, and during the life of any obligation, guaranty or warranty required under said Contract, and shall also
well and truly perform all the undertakings, covenants, terms, conditions, and agreements of any and all modifications of said Contract that may hereafter be made, and shall indemnify and save harmless said Obligee of and from any and all loss,
damage, and expense, including costs and attorneys’ fees, which the Obligee may sustain by reason of Principal’s failure to do so, then this obligation shall be null and void; otherwise it shall remain in full force and effect. 

The Surety agrees that no change, extension of time, alteration, addition, omission, waiver, or other modification of the terms of either the Contract or in the work
to be performed, or in the specifications, or in the plans, or in the contract documents, or any forbearance on the part of either the Obligee or Surety to the other, shall in any way affect said Surety’s obligation on this Bond, and said
Surety does hereby waive notice of any such changes, extensions of time, alterations, additions, omissions, waivers, or other modifications. The parties executing this Bond on behalf of Principal and Surety represent and warrant that they are duly
authorized to bind the Principal and Surety respectively. 
 IN WITNESS WHEREOF, the above bounden parties have executed this instrument under their several
seals this _______ day of __________________, 200_, the name and corporate seal of each corporate seal of each corporate party being hereto affixed and these presents duly signed by its undersigned representative, pursuant to authority of its
governing body. 
  

 A-64 

			
	PRINCIPAL:
	
	  
		
	By:	 	  
	Title:	 	  
	  
	  
	  
	(Principal’s Address)

  

	
	 Witness

	
	   
	 Or Secretary’s Attest

	 [SEAL]

  

			
	SURETY:
	
	  
		
	By:	 	  
	Title:	 	  
	  
	  
	  
	(Surety’s Address)

  

	
	 Witness.

	
	   
	 Or Secretary’s Attest

	 [SEAL]

  

	
	[Attach Power of Attorney executed by attorney-in-fact on behalf of Surety]

  

 A-65 

 ATTACHMENT II - 4 
 DUAL OBLIGEE RIDER FOR PERFORMANCE BOND 
 This Rider is to be attached to and forms a part of
Performance Bond No. ___________________ issued by ____________________________ (hereinafter referred to as “Surety”), as Surety, on the ______ day of ___________________, 20__ (“Performance Bond”). 
 WHEREAS, on or about the ____ day of __________, 200_, ____________________________ (hereinafter called the “Principal”), entered into a
written agreement with ____________________________ (hereinafter called the “Primary Obligee”) for the construction of _____________________ (hereinafter called the “Contract”); and 
 WHEREAS, the Principal and the Surety executed and delivered to said Primary Obligee the Payment Bond No. ____________ (“Payment Bond”) in
connection with the Contract; and 
 WHEREAS, the Primary Obligee has requested the Principal and the Surety to execute and deliver this Dual
Obligee Rider for Performance Bond and the Principal and the Surety have agreed to do so. 
 NOW, THEREFORE, the undersigned hereby agree and
stipulate that Cheniere Sabine Pass Pipeline Company shall be a named obligee (hereinafter referred to as “Additional Obligee”) to the Performance Bond, subject to the conditions set forth below: 
 1. In the event of a material default in performance by the Primary Obligee to the Principal under the terms of the Contract, the right of the Additional
Obligee to recover hereunder shall be subject to the condition that the Additional Obligee remedies said material performance default and thereafter continues to perform as required under the terms of the Contract. 
 2. The aggregate liability of the Surety under the Performance Bond, to any or all of the obligees (Primary and Additional Obligees), as their interests
may appear, is limited to the total penal sum of the Performance Bond. 
 Signed, sealed and dated this ______ day of _____________________,
20__. 
  

			
	PRINCIPAL:
	
	  
		
	By:	 	  
	Title:	 	  
	  
	  
	  
	(Principal’s Address)

  

 A-66 

	
	 Witness

	
	   
	 Or Secretary’s Attest

	 [SEAL]

  

			
	SURETY:
	
	  
		
	By:	 	  
	Title:	 	  
	  
	  
	  
	(Surety’s Address)

  

	
	 Witness.

	
	   
	 Or Secretary’s Attest

	 [SEAL]

  

	
	[Attach Power of Attorney executed by attorney-in-fact on behalf of Surety]

  

 A-67 

 ATTACHMENT III 
 MECHANICAL COMPLETION CERTIFICATE 
 Date: ______________________________ 
 Cheniere Sabine Pass Pipeline Company 
 717 Texas Avenue, Suite 3100

 Houston, Texas 77002 
 Attention: Richard E. Keyser 

 

	Re:	Mechanical Completion Certificate – Sabine Pass Pipeline Project Contract, dated as of February 01, 2006 (the “Agreement”), by and between Cheniere
Sabine Pass Pipeline Company (“Cheniere”) and Willbros Engineers, Inc. (“Willbros”) 

 Pursuant
to Paragraph 8.1 of the Agreement, Willbros hereby certifies that it has completed all requirements under the Agreement for Mechanical Completion with respect to the Sabine Pass Pipeline Project (“Project”), including:
(a) the Work is approved by Cheniere as being ready for pre-commissioning and/or commissioning; (b) Willbros has delivered to Cheniere a set of original test and inspection certificates, including hydrostatic test reports, materials
documentation, MAOP establish records, and internal geometry pig results; (c) Willbros has completed all construction, procurement, fabrication, assembly, erection, installation and testing, including final pipeline hydrostatic tests for the
pipeline and all appropriate appurtenances to ensure that such systems were correctly constructed, procured, fabricated, assembled, erected, installed and tested and are capable of being operated safely and reliably within the requirements contained
in this Agreement; (d) Willbros hereby delivers this Mechanical Completion Certificate as required under Paragraph 8.1 of the Agreement; (e) Willbros has dewatered and dried the pipeline to a dewpoint of negative forty degrees Fahrenheit
(-40oF); (f) Willbros has completed all Exception Items in accordance with Paragraph 8.1 of the Agreement; and (g) Willbros has performed all other obligations required under the Agreement for Mechanical Completion. 
  

	Willbros	certifies that it achieved all requirements under the Agreement for Mechanical Completion on
                    , 200__. 

 Attached is all documentation required to be provided by Willbros under the Agreement to establish that Willbros has achieved all requirements under the Agreement for Mechanical Completion, including the required final pipeline hydrostatic
test reports, materials documentation, MAOP establish records, and internal geometry pig results. 
 IN WITNESS WHEREOF, Willbros has
caused this Mechanical Completion Certificate to be duly executed by its authorized representative and delivered as of the date first written above. 
  

			
	WILLBROS ENGINEERS, INC.
		
	 By: 
	 	  
	 Name: 
	 	  
	 Title: 
	 	 Willbros’ Authorized Representative

	 Date: 
	 	  

  

	cc:	Cheniere Sabine Pass Pipeline Company 

 717 Texas Avenue,
Suite 3100 
 Houston, Texas 77002 
 Attention: Allan Bartz 
  

 A-68 

 ATTACHMENT IV 
 PROJECT COMPLETION CERTIFICATE 
 Date: ____________________________ 
 Cheniere Sabine Pass Pipeline Company 
 717 Texas Avenue, Suite 3100

 Houston, Texas 77002 
 Attention: Richard E. Keyser 

 

	Re:	Project Completion Certificate – Sabine Pass Pipeline Project Contract, dated as of February 01, 2006 (the “Agreement”), by and between Cheniere
Sabine Pass Pipeline Company (“Cheniere”) and Willbros Engineers, Inc. (“Willbros”) 

 Pursuant
to Paragraph 8.3 of the Agreement, Willbros hereby certifies that it has completed all requirements under the Agreement for Project Completion with respect to the Sabine Pass Pipeline Project (“Project”), including:
(a) the successful achievement of Mechanical Completion of all systems for the Project; (b) the successful achievement of Start-up of all systems for the Project; (c) delivery by Willbros of all documentation required to be delivered
under this Agreement, including any Work Product, Cheniere’s Confidential Information and other documentation; (d) delivery by Willbros to Cheniere of fully executed Final Lien and Claim Waivers in the form of Schedule
“A”, Attachment X – Part 2 of the Agreement; (e) removal from the Work Site all of Willbros Personnel, supplies, waste, materials, rubbish and temporary facilities and restoration of the Work Site to its natural
conditions in accordance with this Agreement, Applicable Law and Applicable Codes and Standards or any other requirements of any Governing Authority; (f) Willbros hereby delivers this Project Completion Certificate as required under Paragraph
8.3 of the Agreement; (g) delivery by Willbros to Cheniere of evidence acceptable to Cheniere that all Subcontractors and Vendors have been fully and finally paid, including fully executed Final Lien and Claim Waivers from all Subcontractors
and Major Vendors in the form of Schedule “A”, Attachment X – Part 4 of the Agreement; (h) Willbros has completed all Exception Items in accordance with Paragraph 8.3 of the Agreement; and
(i) performance of all other obligations required by the Agreement for Project Completion. 
 Willbros certifies that it achieved all requirements under
the Agreement for Project Completion on                    , 200__. 
 Attached is all documentation required to be provided by Willbros under the Agreement to establish that Willbros has achieved all requirements under the Agreement for Project Completion, including the required
Willbros, Subcontractor, and Major Vendor Lien and Claim Waivers. 
 IN WITNESS WHEREOF, Willbros has caused this Project Completion
Certificate to be duly executed by its authorized representative and delivered as of the date first written above. 
  

			
	WILLBROS ENGINEERS, INC.
		
	 By: 
	 	  
	 Name: 
	 	  
	 Title: 
	 	 Willbros’ Authorized Representative

	 Date: 
	 	  

  

	cc:	Cheniere Sabine Pass Pipeline Company 

 717 Texas Avenue,
Suite 3100 
 Houston, Texas 77002 
 Attention: Allan Bartz 
  

 A-69 

 ATTACHMENT V 
 START-UP CERTIFICATE 
 Cheniere Sabine Pass Pipeline Company 
 717 Texas Avenue, Suite 3100 
 Houston, Texas 77002 
 Attention: Richard E. Keyser 
  

	Re:	Start-up Certificate – Sabine Pass Pipeline Project Contract, dated as of February 01, 2006 (the “Agreement”), by and between Cheniere Sabine Pass
Pipeline Company (“Cheniere”) and Willbros Engineers, Inc. (“Willbros”) 

 Pursuant to
Paragraph 8.2 of the Agreement, Willbros hereby certifies that it has completed all requirements under the Agreement for Start-up with respect to the Sabine Pass Pipeline Project (“Project”), including: (a) the
successful achievement of Mechanical Completion of all systems for the Project; (b) Cheniere has purged the Project with either natural gas or nitrogen with assistance and support from Willbros as requested; (c) Willbros has completed all
Exception Items in accordance with Paragraph 8.2 of the Agreement; and (d) performance of all other obligations required by the Agreement for Start-up. 
 Willbros certifies that it achieved all requirements under the Agreement for Start-up on                     , 200__. 
 Attached is all documentation required to be provided by Willbros under the Agreement to establish that Willbros has achieved all requirements under the Agreement for
Start-up, including documentation evidencing the completion of all Exception Items required under Paragraph 8.2. 
 IN WITNESS
WHEREOF, Willbros has caused this Start-up Certificate to be duly executed by its authorized representative and delivered as of the date first written above. 
  

			
	WILLBROS ENGINEERS, INC.
		
	 By: 
	 	  
	 Name: 
	 	  
	 Title: 
	 	 Willbros’ Authorized Representative

	 Date: 
	 	  

  

	cc:	Cheniere Sabine Pass Pipeline Company 

 717 Texas Avenue,
Suite 3100 
 Houston, Texas 77002 
 Attention: Allan Bartz 
  

 A-70 

 ATTACHMENT VI 
 CHANGE ORDER FORM 
  

			
	PROJECT NAME: 42-inch Sabine Pass Pipeline Project	  	
		
	COMPANY: Cheniere Sabine Pass Pipeline Company	  	CHANGE ORDER NUMBER: ________________
		
	CONTRACTOR: Willbros Engineers, Inc.	  	DATE OF CHANGE ORDER: ________________
		
	DATE OF AGREEMENT: February 01, 2006	  	

 The Agreement between the Parties listed above is changed as follows: (attach additional documentation
if necessary)  
  

				
	Adjustment to price under the Agreement:	  		
	 The original Guaranteed Maximum Price was
	  	$	67,670,200
	 Net change by previously authorized Change Orders (#________)
	  	$	______
	 The Guaranteed Maximum Price prior to this Change Order was
	  	$	______
	 The Guaranteed Maximum Price will be (increased) (decreased) (unchanged) by this Change Order in the amount of
	  	$	______
	 The new Guaranteed Maximum Price including this Change Order will be
	  	$	______

 Adjustment to dates: 
 The Preparation and Material Receipt Commencement Date will be (increased)(decreased)(unchanged) by ________ (__) calendar days and as a result of this Change Order is now: __________________, 20__. 
 The Construction Commencement Date will be (increased)(decreased)(unchanged) by ________ (__) calendar days and as a result of this Change Order is now:
__________________, 20__. 
 The Scheduled Mechanical Completion Date will be (increased)(decreased)(unchanged) by ________ (__) calendar days and as a
result of this Change Order is now: __________________, 20__. 
 Other impacts to liability or obligation of Willbros or Cheniere under the Agreement:

 Upon execution of this Change Order by Cheniere and Willbros, the above-referenced change shall become a valid and binding part of the original Agreement
without exception or qualification, unless noted in this Change Order. Except as modified by this and any previously issued Change Orders, all other terms and conditions of the Agreement shall remain in full force and effect. This Change Order is
executed by each of the Cheniere’s Authorized Representative and Willbros’ Authorized Representative. 
  

 A-71 

					
	CHENIERE SABINE PASS PIPELINE COMPANY	 		 	WILLBROS ENGINEERS, INC.
			
	   	 		 	   
	 Name
	 		 	 Name

			
	 Cheniere’s Authorized Representative
	 		 	 Willbros’ Authorized Representative

	 Title
	 		 	 Title

			
	   	 		 	   
	 Date of Signing
	 		 	 Date of Signing

  

 A-72 

 ATTACHMENT VII 
 APPROVED SUBCONTRACTORS AND VENDORS LIST 
 The following Subcontractors and Vendors each having subcontracts or
purchase orders of any tier are approved Subcontractors and Vendors for the following portions of the Work: 
  

	I.	Subcontractors 

 Construction
Subcontractors: 
  

	 	•	 	Willbros RPI, Inc. 

  

	 	•	 	Sunland Construction, Inc. 

  

	 	•	 	Associated Pipe Line Contractors, Inc. 

  

	 	•	 	Gregory & Cook Construction, Inc. 

  

	 	•	 	U.S. Pipeline, Inc. 

 Geotechnical Investigation:

  

	 	•	 	Louis J. Capozzoli & Associates, Inc. 

  

	 	•	 	Professional Service Industries, Inc. (PSI) 

  

	 	•	 	Terracon Consultants, Inc. 

  

	 	•	 	Tulonay-Wong Engineers, Inc. 

 Cathodic Protection
System Design: 
  

	 	•	 	Corrpro Co., Inc. 

  

	 	•	 	Mears/CPG, LLC 

  

	 	•	 	MESA Products, Inc. 

 Pipeline Civil Surveying:

  

	 	•	 	Charley Foster & Associates 

  

	 	•	 	Lonnie Harper & Associates 

  

	II.	Vendors 

 Pipe Mills, DSAW:

  

	 	•	 	Oregon Steel-Spiral Weld 

  

	 	•	 	Oregon Steel/Campipe-DSAW Long Seam 

  

	 	•	 	Europipe/Berg 

  

 A-73 

	 	•	 	ILVA (Taronto, Italy) 

  

	 	•	 	IPSCO, Inc. 

  

	 	•	 	Corinth Pipe Works S.A. (CPW) 

 Pipe Mills, ERW:

  

	 	•	 	American Steel Pipe 

  

	 	•	 	Stupp/Manesmann 

  

	 	•	 	LaBarge 

  

	 	•	 	IPSCO, Inc. 

  

	 	•	 	Lone Star 

 Valves, Ball Mainline: 
  

	 	•	 	Cooper-Cameron/Grove/Modern Supply 

  

	 	•	 	Delta Valve (Valvitralia Group-Italy) 

  

	 	•	 	SISCO Specialty Products, Inc. 

  

	 	•	 	Power Valve International 

 Valves, Control:

  

	 	•	 	Fisher 

  

	 	•	 	Masoneilan 

 General Pipe, Valves and Fittings:

  

	 	•	 	McJunkin 

  

	 	•	 	Wilson Supply 

  

	 	•	 	Redman Supply 

 Bolts, Stud and Gaskets:

  

	 	•	 	McJunkin 

  

	 	•	 	Wilson Supply 

  

	 	•	 	Redman Supply 

 Fittings and Flanges (Hy Yield):

  

	 	•	 	SISCO 

  

	 	•	 	LaBarge 

  

	 	•	 	Wilson Supply 

 Bends, Induction: 
  

	 	•	 	Bend Tec 

  

 A-74 

	 	•	 	Shaw 

  

	 	•	 	International Piping Systems 

  

	 	•	 	American Pipe Bending 

 Pig Signal: 
  

	 	•	 	TD Williams 

 Launch/Receiver Package: 

 

	 	•	 	Sagebrush 

  

	 	•	 	Pickett 

  

	 	•	 	Big Inch 

 Regulator Package: 
  

	 	•	 	Sagebrush 

  

	 	•	 	Pickett 

  

	 	•	 	Big Inch 

  

 A-75 

 ATTACHMENT VIII 
 ORGANIZATIONAL CHART 
 

 
  

 A-76 

 ATTACHMENT IX 
 CHENIERE’S HEALTH, SAFETY AND ENVIRONMENTAL POLICIES 
  

	1.	General Guidelines 

 Health, safety and safeguarding
of the environment are within Cheniere’s core values. Willbros shall take into consideration health, safety and the environment (“HSE”) throughout execution of the Work. 
 The minimum approach to the management of HSE issues is generally described in this Attachment IX, and Willbros shall comply with such minimum
requirements and, to the extent possible, maintain the highest level of HSE stewardship for Work of this nature during the execution of the Work. At a minimum, the Work and Willbros’ HSE activities and plans shall comply with: (i) all
Applicable Codes and Standards; (ii) all Applicable Laws, including 29 C.F.R. Part 1910, CERCLA, SARA, and all other applicable environmental laws, regulations and requirements; (iii) the FERC Certificate, and (iv) the most current
FERC-authorized Wetland and Waterbody Construction and Mitigation Procedures and the Upland Erosion Control, Re-vegetation, and Maintenance Plan. 
  

	2.	Safety Management 

 Cheniere’s general HSE
policies shall apply to Willbros and its Subcontractors and Vendors performing Work at the Work Site, and shall apply to the fullest extent practical at all other sites where Work is being performed for Cheniere or where Cheniere personnel are
involved. 
 Willbros shall pay the highest regard to safety and shall conform to all safety-related requirements set forth in the Agreement,
including this Attachment IX and Schedule “D”. 
 Willbros shall be responsible for the safe performance of the Work
under the Agreement, including: (i) the safety of all of the employees, agents, representatives and invitees of Willbros and its Subcontractors and Vendors engaged in the performance of the Work; (ii) ensuring that all Willbros Personnel
are familiar with and will apply all applicable HSE rules and regulations; (iii) providing safety incident reports to Cheniere in accordance with the Agreement; (iv) providing a safe working environment at the Work Site; (v) the safe
performance of the Work by all Willbros Personnel; and (vi) ensuring that awareness of the importance of safety is actively promoted at the Work Site. 
  

	3.	Environmental Management 

 Willbros shall pay the
highest regard to protection of the environment and shall carry out environmental management to ensure that the Work is performed in an environmentally sound manner and in compliance with all provisions of the Agreement, including this Attachment
IX, regarding the environment and Applicable Law. 
  

 A-77 

 Willbros’ objective shall be to ensure, through the proper application of its environmental
protection procedures, that the Work is: (i) managed, planned and engineered to minimize any impact upon the environment; (ii) performed and completed without incidents detrimental to the environment; and (iii) performed in full
compliance with the environmental policy objectives. 
  

	4.	Willbros HSE Plan 

 Willbros shall incorporate all
health, safety and environmental requirements of the Agreement, including this Attachment IX, into Willbros’ HSE plan which it shall implement and adhere to during the performance of the Work. 
 Willbros HSE plan shall contain a full description of the safety and environmental rules, procedures, guidelines, and Work instructions applicable at the
Work Site, which Willbros shall use to ensure the safe and environmentally friendly management of the Work. The HSE plan shall cover all phases of the Work and all activities through Final Acceptance and shall specifically describe safety and
environmental management at the Work Site. 
 The HSE plan shall address all safety and environmental matters relevant to the Work, including
the following: (i) safety meetings and safety events; (ii) safety inspections; (iii) training schedule; (iv) safety reviews at the Work Site; (v) construction safety reviews; (vi) all reasonable emergency response
plans, medical emergency plans; (vii) plans to control the possession and use of firearms, alcohol and controlled substances; and (viii) a Spill Prevent, Control and Countermeasure (SPCC) plan. 
 Cheniere, at its sole discretion, may audit Willbros’ performance of the Work to ensure that the Agreement requirements for safety and the
environment are being satisfied in all respects. Any audits performed shall be based upon Willbros’ safety and environmental manual(s), procedures, and plans. Willbros, at its sole cost, shall immediately correct any nonconformance identified
by Cheniere or its auditors. 
  

 A-78 

 ATTACHMENT X – PART 1 
 WILLBROS’ INTERIM LIEN AND CLAIM WAIVER 
 (To be executed by Willbros with
each invoice other than the final invoice) 
 STATE OF LOUISIANA 
 PARISH OF ___________________ 
 The undersigned, Willbros Engineers, Inc. (“Willbros”), has been engaged under a Pipeline Construction
Contract with Cheniere Sabine Pass Pipeline Company (“Cheniere”), to furnish certain materials, equipment, services, and/or labor for the project known as 42-inch Sabine Pass Pipeline Project (the “Project”), which is located in
Cameron Parish, State of Louisiana described in more detail as follows: 
 _______________________________________________________________________ (the
“Property”). 
 Upon receipt of the sum of U.S.$___________________ (amount in invoice submitted with this Interim Lien and Claim Waiver), Willbros
waives and releases any and all liens or claims of liens against the Project and the Property and all claims, demands, actions, causes of actions or other rights at law, in contract, tort, equity or otherwise that Willbros has or may have against
Cheniere through the date of _______________________, 20___ (date of the invoice submitted with this Interim Lien and Claim Waiver). Exceptions as follows: 
 _______________________________________________________________________________________________ 
 _______________________________________________________________________________________________ 
 (if no exception entry or “none” is
entered above, Willbros shall be deemed not to have reserved any claim.) 
 Willbros represents that all Subcontractors, Vendors, sub-subcontractors and
employees of Willbros have been paid for all work, materials, equipment, services, labor and any other items performed or provided through ___________, 20__ (date of last prior invoice) for the Project. Exceptions as follows: 
 ___________________________________________________________________________________. 
 (if no exception entry or “none” is entered above, all such payments have been made ) 
 This Interim Lien and Claim Waiver is freely and
voluntarily given and Willbros acknowledges and represents that it has fully reviewed the terms and conditions of this Interim Lien and Claim Waiver, that it is fully informed with respect to the legal effect of this Interim Lien and Claim Waiver,
that it has voluntarily chosen to accept the terms and conditions of this Interim Lien and Claim Waiver in return for the payment recited above. 
  

					
	FOR WILLBROS:
	 Applicable to Invoice(s) No. ___

			
	 Signed: 
	 	  	 	 (SEAL)

	 By: 
	 	  	 	
	 Title: 
	 	  	 	
	 Date: 
	 	  	 	

 AFFIDAVIT 
 On this          day of                     ,
20     , before me appeared the above-signed, known or identified to me personally, who, being first duly sworn, did say that s/he is the authorized representative of Willbros and that this document was signed under oath
personally and on behalf of Willbros. 
  

			
	
	  
	 Notary Public

	 My term expires (date):
	 	  

  

 A-79 

 ATTACHMENT X – PART 2 
 WILLBROS’ FINAL LIEN AND CLAIM WAIVER 
 (To be executed by Willbros with the
invoice for final payment) 
 STATE OF LOUISIANA 
 PARISH OF
___________________ 
 The undersigned, Willbros Engineers, Inc. (“Willbros”), has been engaged under an agreement with Cheniere Sabine Pass
Pipeline Company (“Cheniere”), to furnish certain materials, equipment, services, and/or labor for the project known as the 42-inch Sabine Pass Pipeline Project (“Project”), which is located in Cameron Parish, State of Louisiana
and more particularly described as follows: 
 _______________________________________________________________________ (the “Property”).

 Upon receipt of the sum of U.S.$__________________ (amount in invoice for final payment submitted with Willbros’ Final Lien and Claim Waiver),
Willbros waives and releases all liens or claims of liens against the Project and the Property and all claims, demands, actions, causes of actions or other rights at law, in contract, tort, equity or otherwise that Willbros has, may have had or may
have in the future against Cheniere arising out of the agreement or the Project, whether or not known to Willbros at the time of the execution of this Final Lien and Claim Waiver. 
 Willbros represents that all of its obligations, legal, equitable, or otherwise, relating to or arising out of its work on the agreement, Project or subcontracts have been fully satisfied (except for that work and
obligations that survive the termination or expiration of the agreement, including warranties and correction of defective services), including, but not limited to payment to Subcontractors, Vendors and employees and payment of taxes. 
 This Final Lien and Claim Waiver is freely and voluntarily given, and Willbros acknowledges and represents that it has fully reviewed the terms and conditions of this
Final Lien and Claim Waiver, that it is fully informed with respect to the legal effect of this Final Lien and Claim Waiver, and that it has voluntarily chosen to accept the terms and conditions of this Final Lien and Claim Waiver in return for the
payment recited above. Willbros understands, agrees and acknowledges that, upon payment, this document waives rights unconditionally and is fully enforceable to extinguish all claims of Willbros as of the date of execution of this document by
Willbros. 
  

					
	FOR WILLBROS:
	 Applicable to Invoice No(s): ALL     (If all, print “all”)

					
			
	 Signed: 
	 	  	 	 (SEAL)

	 By: 
	 	  	 	
	 Title: 
	 	  	 	
	 Date: 
	 	  	 	

 AFFIDAVIT 
 On this          day of                    ,
20    , before me appeared the above-signed, known or identified to me personally, who, being first duly sworn, did say that s/he is the authorized representative of Willbros and that this document was signed under oath
personally and on behalf of Willbros. 
  

			
	
	  
	 Notary Public

	 My term expires (date):
	 	  

  

 A-80 

 ATTACHMENT X – PART 3 
 SUBCONTRACTORS’ INTERIM LIEN AND CLAIM WAIVER 
 (To be executed by
Subcontractor or Major Vendor [as applicable] with each invoice other than the final invoice) 
 STATE OF LOUISIANA 
 PARISH OF ___________________ 
 The undersigned, ___________________________
(“Subcontractor”) who has, under an agreement with Willbros Engineers, Inc. (“Willbros”), furnished certain materials, equipment, services, and/or labor for the project known as the 42-inch Sabine Pass Pipeline Project (the
“Project”), which is located in Cameron Parish, State of Louisiana described in more detail as follows: 
 _______________________________________________________________________(the “Property”). 
 Upon receipt of the sum of
U.S.$___________________ (“Current Payment”), Subcontractor waives and releases any and all liens or claims of liens against the Project and the Property and all claims, demands, actions, causes of action or other rights at law, in
contract, tort, equity or otherwise that Subcontractor has or may have against Cheniere Sabine Pass Pipeline Company (“Cheniere”) and Willbros through the date of _______________, 20___ (“Current Date”). Exceptions as follows:

 ___________________________________________________________________________________. 
 (if no exception entry or “none” is entered above, Subcontractor shall be deemed not to have reserved any claim.) 
 Subcontractor further represents that all employees, laborers, materialmen, sub-subcontractors and subconsultants employed by Subcontractor in connection with the Project have been paid for all work, materials, equipment, services, labor
and any other items performed or provided through _______________, 20__ (date of last prior Invoice). Exceptions as follows: 
 ___________________________________________________________________________________. 
 (if no exception entry or “none” is entered above,
all such payments have been made) 
 This Subcontractor’s Interim Lien and Claim Waiver is freely and voluntarily given and Subcontractor acknowledges
and represents that it has fully reviewed the terms and conditions of this Subcontractor’s Interim Lien and Claim Waiver, that it is fully informed with respect to the legal effect of this Subcontractor’s Interim Lien and Claim Waiver,
that it has voluntarily chosen to accept the terms and conditions of this Subcontractor’s Interim Lien and Claim Waiver in return for the payment recited above. 
  

					
	FOR SUBCONTRACTOR :
	 Applicable to Invoice(s) No. ___

			
	 Signed: 
	 	  	 	 (SEAL)

	 By: 
	 	  	 	
	 Title: 
	 	  	 	
	 Date: 
	 	  	 	

 AFFIDAVIT 
 On this          day of                    ,
20    , before me appeared the above-signed, known or identified to me personally, who, being first duly sworn, did say that s/he is the authorized representative of Subcontractor and that this document was signed under
oath personally and on behalf of Subcontractor. 
  

			
	
	  
	 Notary Public

	 My term expires (date):
	 	  

  

 A-81 

 ATTACHMENT X – PART 4 
 SUBCONTRACTORS’ FINAL LIEN AND CLAIM WAIVER 
 (To be executed by
Subcontractor or Major Vendor [as applicable] with the invoice for final payment) 
 STATE OF LOUISIANA 
 PARISH OF ___________________ 
 The undersigned,
(“Subcontractor”), has, under an agreement with Willbros Engineers, Inc. (“Willbros”), furnished certain materials, equipment, services, and/or labor for the Project known as the 42-inch Sabine Pass Pipeline Project
(“Project”), which is located in Cameron Parish, State of Louisiana and more particularly described as follows: 
 _______________________________________________________________________(the “Property”). 
 Upon receipt of the sum of
U.S.$                    , Subcontractor waives and releases any and all liens or claims of liens against the Project and the Property,
all claims, demands, actions, causes of action or other rights at law, in contract, tort, equity or otherwise against Cheniere Sabine Pass Pipeline Company (“Cheniere”) or Willbros, and any and all claims or rights against any labor and/or
material bond, which Subcontractor has, may have had or may have in the future arising out of the agreement between Subcontractor and Willbros, the Project or the Property, whether or not known to Subcontractor at the time of the execution of this
Subcontractor’s Final Lien and Claim Waiver. 
 Subcontractor represents that all of its obligations, legal, equitable, or otherwise, relating to or
arising out of the agreement between Willbros and Subcontractor, the Project, the Property or sub-subcontracts have been fully satisfied (except for that work and obligations that survive the termination or expiration of the agreement between
Subcontractor and Willbros, including warranties and correction of defective services), including, but not limited to payment to sub-subcontractors and employees of Subcontractor and payment of taxes. 
 This Subcontractor’s Final Lien and Claim Waiver is freely and voluntarily given and Subcontractor acknowledges and represents that it has fully reviewed the terms
and conditions of this Subcontractor’s Final Lien and Claim Waiver, that it is fully informed with respect to the legal effect of this Subcontractor’s Final Lien and Claim Waiver, and that it has voluntarily chosen to accept the terms and
conditions of this Subcontractor’s Final Lien and Claim Waiver in return for the payment recited above. Subcontractor understands, agrees and acknowledges that, upon payment, this document waives rights unconditionally and is fully enforceable
to extinguish all claims of Subcontractor as of the date of execution of this document by Subcontractor. 
  

					
	FOR SUBCONTRACTOR:
	 Applicable to Invoice No(s). ALL (If all, print “all”)

			
	 Signed: 
	 	  	 	 (SEAL)

	 By: 
	 	  	 	
	 Title: 
	 	  	 	
	 Date: 
	 	  	 	

 AFFIDAVIT 
 On this          day of                    ,
20    , before me appeared the above-signed, known or identified to me personally, who, being first duly sworn, did say that s/he is the authorized representative of Subcontractor and that this document was signed under
oath personally and on behalf of Subcontractor. 
  

			
	
	  
	 Notary Public

	 My term expires (date):
	 	  

  

 A-82 

 SCHEDULE “B” 
 SCOPE OF WORK FOR THE PROJECT 
 TABLE OF CONTENTS

  

			
	 1. PROJECT MANAGEMENT AND ENGINEERING
	  	B-2
	 2. MATERIAL PROCUREMENT
	  	B-3
	 3. CONSTRUCTION MANAGEMENT
	  	B-4
	 4. CONSTRUCTION
	  	B-5
	 5. DELIVERABLES
	  	B-6
	 ATTACHMENT I WORK SITE
	  	B-7
	 ATTACHMENT II FLOW SCHEMATIC
	  	B-8

  

 B-1 

 SCHEDULE “B” 
 SCOPE OF WORK FOR THE PROJECT 
 Willbros shall perform the Project management, engineering,
material procurement, construction management and construction for the Project as described in the Agreement and herein, including providing all deliverables described below. 
 1. PROJECT MANAGEMENT AND ENGINEERING 
 A Willbros project manager shall provide
management and direction for the Project. Project controls shall maintain a detailed Work Plan with activities planned for the Work as set forth in Paragraph 6 of Schedule “A”. Following construction, Willbros will assemble
completion report data, hydrostatic test records, non-destructive testing records, internal geometry pig results, Vendor data and material certifications, MAOP establishment records, and other inspection certificates. 
 Without limiting the generality of the foregoing, the Project management and engineering portion of the Work to be performed by Willbros shall include: 
  

	1.1	Perform Project management, controls and reporting; 

  

	1.2	Prepare design basis document using the following design parameters: 

  

			
	Class Locations (to be field verified)	  	
	 Class 1
	  	MP 0 to MP 11
	 Class 3
	  	MP 11 to MP 16
	Design Pressure, psig	  	1440
	Operating Temperature, oF	  	20 - 100
	Corrosion Allowance, inches	  	nil
	Pipe Diameter, inches	  	42
	Pipe W.T. and Grade	  	
	 F = 0.72
	  	0.600” API 5L - X70
	 F = 0.60
	  	0.700” API 5L - X70
	 F = 0.50
	  	0.864” API 5L - X70
	External Coatings	  	
	 FBE
	  	14 - 16 mils
	 Ruff Coat or equal
	  	
	             (for concrete coated pipe)
	  	3 - 5 mils (in addition to FBE)
	 Abrasion Resistant Coating (for road bores)
	  	32 mils
	 Internal Liquid Epoxy Coating
	  	1.5 mils
	Minimum Bend Radius for Pigging	  	5 pipe diameters
	Concrete Weight Coating	  	6” thick, 190 pcf (0.600” W.T. pipe)
		  	 5” thick, 190 pcf (0.864” W.T. pipe)

  

	1.3	Perform population density analysis to finalize class locations; 

  

 B-2 

	1.4	Perform field reconnaissance and gather site specific data at appurtenance locations and crossings, including foreign pipeline crossings; 

  

	1.5	Provide engineering input for permit applications, in accordance with Paragraph 2.3 of Schedule “A”; 

  

	1.6	Perform detailed design of the pipeline and all ancillary facilities of the Project, with reference to the flow schematic located in Attachment II; 

 

	1.7	Prepare Drawings and Specifications with bills-of-materials and construction typicals, in accordance with the Agreement, including Schedule “D”, and Paragraphs 2.7
and 2.8 of Schedule “A”; 

  

	1.8	Modify, as required and in accordance with this Agreement, the Cheniere-provided drawings listed in Paragraph 5.3 of Schedule “A”. 

  

	1.9	Perform geotechnical investigations at monitor-regulator and scraper launcher site; 

  

	1.10	Perform cathodic protection system design; 

  

	1.11	Prepare construction Specifications with hydrostatic test plan, in accordance with Schedule “D”; 

  

	1.12	Prepare job data books which will including hydrostatic test records, welding records, as-built Drawings, certified Vendor Drawings, material certifications, operating and
maintenance instructions for purchased equipment, spare parts lists, Warranties, as-built survey data and results of the internal geometry pig results in an electronic format compatible with the GIS of Cheniere’s choice;

  

	1.13	Provide engineering support during construction, commissioning and Start-up of the Project; and 

  

	1.14	Prepare construction bid solicitation packages, solicit bids, analyze bids and award construction Work to a bidder , in accordance with Paragraphs 3.3, 3.4, and 3.5 of Schedule
“A”. 

 2. MATERIAL PROCUREMENT 
 The procurement portion of the Work to be performed by Willbros shall include: 
  

	2.1	Develop major material Specifications, in accordance with Schedule “D”, and solicit and evaluate bids for such materials; 

  

	2.2	Issue purchase orders for all permanent materials and provide shipping instructions to Vendors; 

  

	2.3	Expedite and coordinate material shipments; 

  

	2.4	Review and approve Vendor Drawings and data submittals; 

  

	2.5	Obtain material certification records; 

  

	2.6	Process material receiving reports and Vendor invoices; 

  

 B-3 

	2.7	Make timely and appropriate payments to Vendors; 

  

	2.8	Perform the following inspections at the Vendor’s plant before material shipment: 

  

	 	2.8.1 	Pipe mill (review manufacturing procedures, attend pre-production meeting, and perform inspections during pipe manufacturing); 

  

	 	2.8.2 	Fusion-bonded epoxy coating; 

  

	 	2.8.3 	Concrete coating; 

  

	 	2.8.4 	Launcher skid; and 

  

	 	2.8.5 	Monitor regulator skid; 

  

	2.9	Receive, inspect and inventory materials at the Work Site; and 

  

	2.10	Provide recommended spare parts list for commissioning, operations and maintenance (spare parts may, at Cheniere’s sole discretion, be purchased by Cheniere); the cost of such
spare parts is not included within the Guaranteed Maximum Price. 

 3. CONSTRUCTION MANAGEMENT 
 A field office staffed with Willbros Personnel including a field project manager, an office manager/assistant will be established at the Work Site in the Johnson’s
Bayou area, in accordance with Paragraph 4.2 of Schedule “A”. Inspection services will be subcontracted to a qualified firm or self-performed by Willbros in accordance with Paragraph 7 of Schedule “A”. The
construction survey will include a 5-man crew for construction staking and a 2-man and 3-man crew for as-built surveys. These crews will by supervised by Willbros’ chief supervisor. 
 Without limiting the generality of the foregoing, the construction management portion of the Work to be performed by Willbros shall include: 
  

	3.1	Prepare digital alignment maps, showing the pipeline centerline, property ownership and land base information; 

  

	3.2	Prepare road crossing permit Drawings; 

  

	3.3	Perform pre-construction staking for the pipeline, including sites for scraper launcher, monitor regulator station, side valves, mainline valves and other pipeline appurtenances;

  

	3.4	Perform pre- and post-construction topographic civil surveys of the wetlands crossed within the pipeline right-of-way between stations 62+35 and 480+34 to confirm ground
contour restoration at the conclusion of construction is in accordance with the FERC certificate. The surveys will be conducted at the time of restoration and used to ensure compliance prior to demobilization of the construction Subcontractor.
Drawing exhibits with the location of the surveys and cross-sections of the pre- and post-construction transects will be prepared. The pre- and post-construction ground elevation tolerance shall be minus zero (0), plus six (6) inches;

  

 B-4 

	3.5	Perform as-built surveys and prepare as-built Drawings following construction in accordance with Schedule “D” and Paragraphs 2.7 and 2.8 of Schedule
“A”. All survey information shall be geo-referenced. Survey data processing will be performed so that all data collected is delivered in an electronic format compatible with the GIS of Cheniere’s choice; 

 

	3.6	Perform construction inspection through a qualified independent third party to ensure that construction meets the requirements of the Specifications, Drawings, easements, Applicable
Law, Applicable Codes and Standards, permit provisions and all other requirements of construction included in the Agreement; and 

  

	3.7	Provide commissioning and Start-up support, as required by Cheniere, excluding gas handling services. 

 4. CONSTRUCTION 
 The construction portion of the Work to be performed by Willbros or its
Subcontractors shall include: 
  

	4.1	Perform pipeline construction, including clearing, grading, stringing, bending, ditching, laying, welding, coating, tie-ins, lowering-in, backfilling, testing and cleanup;

  

	4.2	Install pipeline monitor regulator station, pig launcher, side valves, mainline valves, and pipeline appurtenances (CP test stations and line markers). The outlet end of the
pipeline will have a weld cap with 2-inch coupling, nipple, plug valve and plug; 

  

	4.3	Perform internal geometry pig survey on the completed pipeline construction prior to the introduction of natural gas or nitrogen to verify that there are no dents with dimensions
greater than what 49 C.F.R. Part 192 or ASME B31.8 codes allow; 

  

	4.4	Install pre-fabricated assemblies, including: 

  

	 	4.4.1 	Monitor-regulator station (skid-mounted) on pile-supported platform; 

  

	 	4.4.2 	Pig launcher (skid-mounted) on pile-supported platform; and 

  

	 	4.4.3 	30-inch NGPL side tap; 

  

	 	4.4.4 	42-inch mainline valve assembly; and 

  

	 	4.4.5 	42-inch mainline valve and 42-inch side valve; 

  

	4.5	De-water, clean and dry the interior of the pipeline using a series of displacement and cleaning pigs propelled by dry air to achieve a dew point of negative forty degrees
Fahrenheit (-40oF) or less. After drying, the pipeline will be shut-in and pressurized to five (5) psig with dry air. 

  

	4.6	Tie-in pipeline to liquefied natural gas terminal at launcher site; tie-in at Johnson’s Bayou will be by others; 

  

	4.7	Perform site Work at the Work Site, including installation of chain link fence with drive-through and walk gates, grading and installation of rock; 

  

 B-5 

	4.8	Perform Non-destructive testing (NDT) through a qualified third party inspector; radiography inspection shall be performed on 100-percent of girth welds, and a NDT auditor shall be
required; and 

  

	4.9	Cheniere shall provide Willbros access to and use of Cheniere’s dock at the liquefied natural gas terminal for offloading pipe and major equipment skids from barges. Cheniere
shall also provide access to and use of a yard at the liquefied natural gas terminal for staging and pipe storage. Willbros may, with Cheniere’s prior written approval, use an alternate docking facility and/or yard in the Work Site.

 5. DELIVERABLES 
 The following deliverables are considered part of the Work and shall be provided by Willbros during the development and execution of the Project: 
  

	5.1	Drawings (refer to Attachment I of Schedule “D”) 

  

	5.2	Specifications (refer to Attachment II of Schedule “D”) 

  

	5.3	Job Data Book 

  

	 	5.3.1 	Hydrostatic tests 

  

	 	5.3.2 	Material purchase orders 

  

	 	5.3.3 	Material certifications 

  

	 	5.3.4 	Certified Vendor Drawings 

  

	 	5.3.5 	Operating and maintenance instructions for purchased equipment 

  

	 	5.3.6 	Spare parts lists 

  

	 	5.3.7 	Warranties 

  

	 	5.3.8 	As-built Drawings (with GIS compatible data) 

  

	 	5.3.9 	Welder qualifications 

  

	 	5.3.10 	Welding procedure(s) 

  

	 	5.3.11 	Weld records summary 

  

	 	5.3.12 	Internal geometry pig results (with GIS compatible data) 

  

	5.4	Administrative 

  

	 	5.4.1	Monthly progress and cost status reports 

  

	 	5.4.2	Monthly Project Schedule updates 

  

	 	5.4.3	Monthly procurement status reports 

  

	 	5.4.4	Meeting notes 

  

 B-6 

 ATTACHMENT I 
 WORK SITE 
 

 
 Proposed 42” Natural Gas Pipeline Project 
  

 B-7 

 ATTACHMENT I I 
 FLOW SCHEMATIC 
  

 B-8 

 SCHEDULE “C” 
 INTENTIONALLY OMITTED 
  

 C-1 

 SCHEDULE “D” 
 APPLICABLE CODES AND STANDARDS, DRAWINGS AND SPECIFICATIONS 
 TABLE
OF CONTENTS 
  

			
	 1. APPLICABLE CODES AND STANDARDS
	  	D-2
		
	 2. DRAWINGS
	  	D-3
		
	 3. SPECIFICATIONS
	  	D-3
		
	 ATTACHMENT I DRAWINGS
	  	D-4
		
	 ATTACHMENT II SPECIFICATIONS
	  	D-5

  

 D-1 

 SCHEDULE “D” 
 APPLICABLE CODES AND STANDARDS, DRAWINGS AND SPECIFICATIONS 
 1.
APPLICABLE CODES AND STANDARDS 
 During the execution of the Work, Willbros shall comply with the latest edition of the following Applicable Codes
and Standards, irrespective of the specification of any earlier date or edition. In the event of a conflict between the Applicable Codes and Standards and the Specifications, Willbros shall promptly notify Cheniere of the conflict. The specific
Applicable Codes and Standards listed in this Schedule with respect to each organization (e.g., API) are not meant to be an exclusive list of such Applicable Codes and Standards that must be adhered to with respect to each such organization as they
are applicable to the Work. 
 The Project and all related facilities will be designed in accordance with Part 192, Title 49 of the Code of
Federal Regulations “Transportation of Natural and Other Gas By Pipeline: Minimum Federal Safety Standards” (latest edition). 
  

			
	AASHTO	  	American Association of State Highway and Transportation Officials
	AISC	  	American Institute of Steel Construction
	ANSI	  	American National Standards Institute
	API	  	American Petroleum Institute
	ASCE	  	American Society of Civil Engineers
	ASME	  	American Society of Mechanical Engineers
	ASTM	  	American Society of Testing and Materials
	AWS	  	American Welding Society
	EPA	  	Environmental Protection Agency
	FM	  	Factory Mutual
	IEEE	  	Institute of Electrical and Electronics Engineers
	IES	  	Illuminated Engineering Society
	ISA	  	Instrument Society of America
	MSS	  	Manufacturers Standardization Society of the Valve and Fitting Industry
	NACE	  	National Association of Corrosion Engineers
	NEMA	  	National Electrical Manufacturers Association
	NFPA	  	National Fire Protection Association
	OSHA	  	Occupational Safety and Health Act
	UBC	  	Uniform Building Code
	UL	  	Underwriters Laboratories
	NEC	  	National Electrical Code (NFPA 70)

  

 D-2 

 2. DRAWINGS 
 Willbros shall provide the Drawings listed in Attachment I of this Schedule “D” in accordance with this Agreement. 
 3. SPECIFICATIONS 
 The Specifications include the material/equipment specifications, design
specifications, construction specifications, and inspection specifications included in Attachment II of this Schedule “D”. 
 END OF SCHEDULE “D” 
  

 D-3 

 ATTACHMENT I 
 DRAWINGS 
 1. FERC Alignment Sheets 
 2. Construction Alignment Drawings 
 3. As-Built Alignment Drawings 
 4. Highway Crossing Plan/Profile 
 5. Typical Parish Road Crossing

 6. Site Specific Wetland Construction Plan 
 7. Hydrostatic
Test Profile 
 8. Foreign Pipeline Crossings 
 9. Construction
Typicals 
 10. Notes and Legend Sheet 
 11. Scraper Launcher
and Inlet Pressure Regulator Plot Plan 
 12. Side Valve Plan and Elevation 
 13. Mainline Valve Plan and Elevation 
 14. Scraper Launcher and Monitor Regulator Platforms 
 15. Pile and Pile Cap Details and Plot Plans 
 16. Fence Standard

 17. Monitor Regulator Skid Layout 
 18. Scraper Launcher Skid
Layout 
 19. Scraper Launcher Piping Hookup Details 
 20.
Monitor Regulator Piping Hookup Details 
 21. Pipeline System P&ID 
 22. Valve Operator Details 
  

 D-4 

 ATTACHMENT II 
 SPECIFICATIONS 
 1. Submerged Arc Welded Line Pipe Longitudinal Seam 
 2. Submerged Arc Welded Line Pipe Helical Seam 
 3. Stock Pipe Seamless, SAW
and ERW 
 4. Handling, Storage and Shipment of Line Pipe 
 5.
Yard Applied Pipe Coating 
 6. Yard Application of Concrete Coating to Pipe 
 7. Internal Coating of Line Pipe 
 8. Induction Bending of Line Pipe 
 9. High Strength Wrought Welding Fittings 
 10. Application of Protective
Coating Systems 
 11. Valve Procurement (API 6D, 12-inch and larger) 
 12. Pneumatic Quarter Turn Valve Operators 
 13. Pressure Regulation Valves 
 14. Line Pipe Inspection 
 15. Geotechnical Investigation 
 16. Construction of Pipeline and Related Facilities 
 17. Hydrostatic Test Plan 
 18. Welding Procedures 
 19. As-Built Survey Procedure 
  

 D-5 

 SCHEDULE “E” 
 INTENTIONALLY OMITTED 
  

 E-1 

 SCHEDULE “F” 
 PROJECT SCHEDULE 
  

 F-1 

 

 
  

 F-2 

 

 
  

 F-3Gas Purchase and Sale Agreement

 Exhibit 10.2 
 GAS PURCHASE AND SALE AGREEMENT 
 between 
 Cheniere LNG Marketing, Inc., 
 as
Seller, 
 and 
 PPM
Energy, Inc., 
 as Buyer 
 Dated April 4, 2006 
 Execution Version 

 TABLE OF CONTENTS 
  

					
	ARTICLE I	  	DEFINITIONS AND INTERPRETATION	  	1
			
	ARTICLE II	  	TERM	  	8
			
	ARTICLE III	  	QUANTITY	  	8
			
	ARTICLE IV	  	PRICE	  	13
			
	ARTICLE V	  	DELIVERY POINT	  	14
			
	ARTICLE VI	  	TRANSPORTATION	  	14
			
	ARTICLE VII	  	QUALITY AND MEASUREMENT	  	15
			
	ARTICLE VIII	  	TERMINATION	  	16
			
	ARTICLE IX	  	BILLING, PAYMENT AND AUDIT	  	16
			
	ARTICLE X	  	TITLE, WARRANTY AND INDEMNITY	  	18
			
	ARTICLE XI	  	FORCE MAJEURE	  	18
			
	ARTICLE XII	  	DEFAULTS AND REMEDIES	  	22
			
	ARTICLE XIII	  	DISPUTE RESOLUTION	  	24
			
	ARTICLE XIV	  	CREDIT SUPPORT	  	26
			
	ARTICLE XV	  	MISCELLANEOUS	  	27

  

					
	Exhibit A:	  	Map of Cheniere Creole Trail Pipeline and Cheniere Sabine Pass Pipeline	  	
			
	Exhibit B:	  	Form of Increase Notice	  	
			
	Exhibit C:	  	Buyer Guarantee	  	
			
	Exhibit D:	  	Seller Guarantee	  	

  

 i 

 Gas Purchase and Sale Agreement 
 This Gas Purchase and Sale Agreement (“Agreement”), dated as of this 4th day of April, 2006 (“Effective Date”) is made by and between PPM Energy, Inc., a company incorporated under the laws of the
state of Oregon (“Buyer”) and Cheniere LNG Marketing, Inc., a company incorporated under the laws of the state of Delaware (“Seller”). Buyer or Seller may be referred to herein as “Party” and collectively Buyer and
Seller may be referred to as “Parties.” 
 RECITALS 
 WHEREAS, as one facet of its Gas marketing portfolio, Seller intends to purchase LNG for import into the United States, regasify such LNG into Gas and sell such Gas in the North American market; 
 WHEREAS, affiliates of Seller are developing LNG regasification terminals, including the Sabine Pass LNG Terminal, and are developing Gas pipelines, including the
Cheniere Sabine Pass Pipeline and the Cheniere Creole Trail Pipeline; 
 WHEREAS, Seller has or intends to acquire contractual rights to certain LNG
terminalling services (including the regasification of LNG) at the Sabine Pass LNG Terminal; 
 WHEREAS, Seller has or intends to acquire
transportation rights on the Cheniere Sabine Pass Pipeline and the Cheniere Creole Trail Pipeline, on the understanding that deliveries of Gas from the Cheniere Sabine Pass Pipeline will be able to be made to the Cheniere Creole Trail Pipeline at or
upstream of the Delivery Point(s), thereby allowing regasified LNG from the Sabine Pass LNG Terminal to be delivered at the Delivery Point(s); and 
 WHEREAS, subject to the fulfillment of certain conditions (including the acquisition by Seller of sufficient LNG supply not dedicated to the supply of Seller’s other customers), Seller desires to sell Gas to Buyer at the
Delivery Point(s) beginning at a minimum quantity of 20,000 MMBtu per day, and potentially increasing up to a maximum of 600,000 MMBtu per day, and Buyer desires to purchase such Gas from Seller; 
 NOW, THEREFORE, for good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged by the Parties hereto and for the mutual
covenants contained herein, Buyer and Seller hereby agree as follows: 
 ARTICLE I 
 DEFINITIONS AND INTERPRETATION 
  

	A.	Capitalized terms defined in this Article I shall have the meanings set forth below. 

 “AAA” has the meaning ascribed to the term in Section XIII.A. 
 “Adjusted Daily Contract Quantity” or
“ADCQ” has the meaning ascribed to the term in Section III.C.1. 
  

 1 

 “Affiliate” means a Person (other than a Party) that directly or indirectly controls, is controlled by, or is
under common control with a Party to this Agreement, and for such purposes the terms “control”, “controlled by” and other derivatives shall mean the direct or indirect ownership of more than fifty percent (50%) of the voting
rights in a Person. 
 “Aggregate Exposure” means, as of the relevant date of determination, the sum of (a) the aggregate amount of the Daily
Exposure in respect of each day on which Gas has been delivered to and received by Buyer in accordance with this Agreement, to the extent that Buyer has not yet been invoiced in accordance with Article IX in respect of such Gas, and (b) the
aggregate amount owing by Buyer to Seller in respect of Gas delivered to and received by Buyer in accordance with this Agreement for which Buyer has been invoiced as of such date in accordance with Article IX. 
 “Aggregate Exposure Notice” means the notice from Seller to Buyer as required by Section III.C.1.d. that the Aggregate Exposure exceeds the Guarantee
Limitation Amount, which written notice must be provided to Buyer at least five (5) Business Days prior to Bid Week for the delivery month. 
 “Agreement” has the meaning ascribed to the term in the preamble to this Agreement and includes all Exhibits attached hereto and made a part hereof. 
 “Bid Week” means the week during which the New York Mercantile Exchange’s Henry Hub natural gas futures contract for the immediately following month terminates. 
 “British thermal unit” or “Btu” means the International BTU, which is also called the Btu (IT). 
 “Business Day” means any day except Saturday, Sunday or days that New York Mercantile Exchange, Inc., schedules as holidays. 
 “Buyer” has the meaning ascribed to the term in the preamble to this Agreement. 
 “Buyer Guarantee” means the guarantee dated as of the date hereof given by Buyer Guarantor to Seller guaranteeing the obligations of Buyer under this Agreement, a true and correct copy of which is attached
as Exhibit C. 
 “Buyer Guarantor” means Scottish Power Finance (US) Inc., Delaware corporation. 
 “Buyer’s Cumulative Interruption Account” means the cumulative amount of the positive difference between the Seller’s Non-Performance Payment and the
amount of Seller’s payments to Buyer pursuant to Section III.D.2. over a period of twenty-four (24) months, the first such period to begin with the Commercial Start Date; provided, however, that if the Buyer’s Cumulative Interruption
Account balance is reduced pursuant to Section III.B.3.e., Section III.D.2.b. or Section VIII.B.3., the date of the reduction constitutes the beginning of a new twenty-four (24) month period. 
 “Cheniere Creole Trail Pipeline” means that pipeline, a preliminary map of which is attached as Exhibit A, commencing at or near the future site of the Creole
Trail LNG Terminal and terminating at an interconnection with Columbia Gulf Transmission Company pipeline. 
  

 2 

 “Cheniere Sabine Pass Pipeline” means that pipeline, a preliminary map of which is attached as Exhibit A,
commencing at the tailgate of the Sabine Pass LNG Terminal and terminating approximately sixteen (16) miles east at Johnson Bayou. 
 “Claims”
has the meaning ascribed to it in Section X.C. 
 “Commercial Start Date” means the first day of the second calendar month following the later of
the date of the commencement of: (a) commercial operation of the Sabine Pass LNG Terminal; (b) commercial operation of the Cheniere Creole Trail Pipeline with firm service to the delivery points at the Principal Pipelines; and (c) the
commercial delivery of Gas from the Sabine Pass LNG Terminal to the Cheniere Creole Trail Pipeline. 
 “Contract Price” has the meaning ascribed to
the term in Section IV.A.1. 
 “Cover Standard” means that if there is an unexcused failure to take or deliver any quantity of Gas pursuant to this
Agreement, then the performing Party shall use commercially reasonable efforts to (i) if Buyer is the performing Party, obtain Gas, (or an alternate fuel if elected by Buyer and replacement Gas is not available), or (ii) if Seller is the
performing Party, sell Gas, in either case, at a price reasonable for the delivery or production area, as applicable, consistent with: the amount of notice provided by the nonperforming Party; the quantities involved; and the anticipated length of
failure by the nonperforming Party. 
 “Creole Trail LNG Terminal” means the LNG terminal facility in Cameron Parish, Louisiana capable of
performing certain LNG terminalling services, including: the berthing of LNG vessels; the unloading, receiving and storing of LNG; the regasification of LNG; and delivery of natural gas to the point of interconnect between the tailgate of such LNG
terminal facility and the Cheniere Creole Trail Pipeline. 
 “Daily Contract Quantity” or “DCQ” has the meaning ascribed to the term in
Section III.B.1. 
 “Daily Exposure” means, as of the relevant date of determination, an amount equal to the product obtained by multiplying
(a) the DCQ in respect of such date, by (b) the relevant price as determined in accordance with Article IV. 
 “Defaulting Party” has the
meaning ascribed to the term in Section XII.A. 
 “Delivery Point(s)” has the meaning ascribed to the term in Section V.A. 
 “Dispute” means any dispute, controversy or claim (of any and every kind or type, whether based on contract, tort, statute, regulation, or otherwise) arising
out of, relating to, or connected with this Agreement, including any dispute as to the construction, validity, interpretation, termination, enforceability or breach of this Agreement. 
 “Early Termination Date” has the meaning ascribed to the term in Section XII.C. 
 “Effective Date” has
the meaning ascribed to the term in the preamble to this Agreement. 
 “Event of Default” has the meaning ascribed to the term in Section XII.A.

  

 3 

 “Excused Party” has the meaning ascribed to the term in Section XI.A. 
 “Extension Term” has the meaning ascribed to the term in Section II.C. 
 “FERC” means the Federal Energy Regulatory Commission, or any successor federal regulatory agency. 
 “FERC Gas Tariff” means
the rate schedules, terms and conditions of service and other components comprising a natural gas company’s tariff as required to be on file with FERC and in effect, as it may be modified from time to time. 
 “Force Majeure” has the meaning ascribed to the term in Section XI.B. 
 “Gas” means any mixture of hydrocarbons and noncombustible gases in a gaseous state consisting primarily of methane. 
 “Gas
Day” means a period beginning at 09:00 Central Clock Time and ending at 09:00 Central Clock Time on the following day. 
 “Gas Quality
Standard” has the meaning ascribed to the term in Section VII.A. 
 “Government Approvals” means all consents, authorizations, licenses,
waivers, permits, approvals and other similar documents from or by any federal, regional, state, or local government, any subdivision, agency, commission or authority thereof (including maritime authorities, port authority or any quasi-governmental
agency) having jurisdiction over a Party, the Sabine Pass LNG Terminal, the Creole Trail LNG Terminal, the Cheniere Sabine Pass Pipeline, the Cheniere Creole Trail Pipeline, as the case may be, and acting within its legal authority. 
 “Guarantee Limitation Amount” has the meaning ascribed to such term in the Buyer Guarantee. 
 “Gulf of Mexico” means that body of water located at the southeastern corner of North America, that is approximately 579,000 square miles, measuring approximately 995 miles from east to west, 560 miles from
north to south and that is bordered by the United States to the north, Mexico to the west, and the island of Cuba to the southeast. 
 “Imbalance
Charges” mean any fees, penalties, costs or charges (in cash or in kind) assessed by a Transporter for failure to satisfy the Transporter’s balance and/or nomination requirements. 
 “Increase Notice” has the meaning ascribed to the term in Section III.B.3. 
 “Initial Term” has the meaning ascribed to the term in Section II.B. 
 “Interconnect Pipeline” has the
meaning ascribed to the term in Section V.A. 
 “Interruption of LNG Supply” means any act, event or circumstance, not reasonably within the
control of Seller, the effects of which could not be avoided or remedied by the commercially reasonable efforts of Seller, and which would not otherwise qualify as Force Majeure hereunder, 

  

 4 

 
that prevents or delays LNG from being delivered to the Sabine Pass LNG Terminal, including, for greater certainty: (i) breakdown or loss of an LNG
Tanker or its cargo, (ii) interruption of LNG supply from the country from which Seller sources LNG, including breakdown or loss of any LNG liquefaction facilities in such country; and (iii) the loss or failure of Seller’s LNG supply
or depletion of reserves of gas used to produce LNG. 
 “LNG” means Gas in a liquid state at or below its boiling point at a pressure of
approximately one (1) atmosphere. 
 “LNG Tanker” means an ocean-going vessel suitable for transporting LNG. 
 “LNG Terminals” means the Creole Trail LNG Terminal or the Sabine Pass LNG Terminal. 
 “Long-Term LNG Supply Agreement” means an LNG supply agreement entered into by Seller or its Affiliates for the supply of LNG that meets the following criteria: 
  

	 	i.	the initial term of such agreement is two (2) years or greater; 

  

	 	ii.	the volume equates to a delivery rate for regasified LNG equal to or greater than one hundred thousand (100,000) MMBtu per Gas Day for the entire initial term of such
agreement; 

  

	 	iii.	the contract price for the purchase of LNG, as converted into a price per MMBtu is equivalent to not more than ninety-four percent (94%) of the final NYMEX settlement price per
MMBtu for a delivery month, less $0.32 per MMBtu, over the remaining Term or the initial term of the LNG supply agreement, whichever is shorter; 

  

	 	iv.	the primary destination of the LNG is the Sabine Pass LNG Terminal; 

  

	 	v.	such LNG supply agreement is not a Paired Contract; and 

  

	 	vi.	at the time of execution the DCQ is less than the Maximum DCQ. 

 “Maximum DCQ” means six hundred thousand (600,000) MMBtu per Gas Day, unless otherwise modified pursuant to Section III.B.4. 
 “MMBtu” means one million (1,000,000) British thermal units. 
 “Net Settlement Amount” has the meaning ascribed to the
term in Section XII.C. 
 “Non-Defaulting Party” has the meaning ascribed to the term in Section XII.A. 
 “Paired Contract” means an LNG supply agreement to the extent that LNG supplied under such agreement supports Seller’s or its Affiliate’s obligations
under one or more particular regasified LNG sales agreements, each executed by Seller or its Affiliate prior to the Effective Date, or if not executed prior to the Effective Date, each executed by Seller or its Affiliate within six (6) months
of the other. 
  

 5 

 “Party” and “Parties” have the meanings ascribed to the terms in the preamble to this Agreement.

 “Payment Date” means the later of (a) the 25th day of the month following the month of delivery of Gas; provided Buyer has received the
invoice for such month from Seller, and (b) the 10th day following Buyer’s receipt of an invoice from Seller. 
 “Person” means any
individual, company, firm, partnership, association or body corporate. 
 “Principal Pipelines” means the following pipelines that interconnect
with the Cheniere Creole Trail Pipeline: 
  

	 	i.	Transcontinental Gas Pipe Line Corporation (Zone 3); 

  

	 	ii.	Tennessee Gas Pipe Line Company; 

  

	 	iii.	Florida Gas Transmission Company (Zone 2); 

  

	 	iv.	Columbia Gulf Transmission Company; and 

  

	 	v.	ANR Pipeline Company, 

 each as described in the Cheniere Creole Trail
Pipeline application for certificate of authority filed at FERC, and as shown on Exhibit A, subject to any modifications that may be required or approved by FERC. 
 “Sabine Pass LNG Terminal” means the LNG terminal facility in Cameron Parish, Louisiana capable of performing certain LNG terminalling services, including: the berthing of LNG vessels; the unloading, receiving and storing of LNG;
the regasification of LNG; and the delivery of natural gas to the point of interconnect between the tailgate of such LNG terminal facility and the Cheniere Sabine Pass Pipeline. 
 “Scheduled Maintenance” has the meaning ascribed to the term in Section III.C.3. 
 “Seller” has the
meaning ascribed to the term in the preamble to this Agreement. 
 “Seller Guarantee” means the guarantee dated as of the date hereof given by
Seller Guarantor to Buyer guaranteeing the obligations of Seller under this Agreement, a true and correct copy of which is attached as Exhibit D. 
 “Seller Guarantor” means Cheniere Energy, Inc., a Delaware corporation. 
 “Seller’s Cumulative Interruption Account” means
the cumulative amount of damages paid by Seller to Buyer pursuant to Section III.D.2. over a period of twenty-four (24) months, the first such period to begin on the Commercial Start Date; provided, however, that if the Seller’s Cumulative
Interruption Account balance is reduced pursuant to Section VIII.A.4., the date of the reduction constitutes the beginning of a new twenty-four (24) month period. 
 “Seller’s Non-Performance Payment” has the meaning ascribed to the term in Section III.D.1. 
  

 6 

 “Spot Price” means the midpoint price listed in the publication “Platt’s Gas Daily” (or, if no
longer published, any successor publication or equivalent publication as may be mutually agreed to by the Parties), under the listing applicable to the geographic location closest in proximity to the Delivery Point(s) for the relevant Gas Day;
provided, if there is no single price published for such location for such Gas Day, but there is published a range of prices, then the Spot Price shall be the average of such high and low prices. If no price or range of prices is published for such
Gas Day, then the Spot Price shall be the average of the following: (i) the price (determined as stated above) for the first Gas Day for which a price or range of prices is published that next precedes the relevant Gas Day; and (ii) the
price (determined as stated above) for the first Gas Day for which a price or range of prices is published that next follows the relevant Gas Day. 
 “Taxes” has the meaning ascribed to the term in Section IV.B.2. 
 “Term” has the meaning ascribed to the term in Section II.A.

 “Transporter” means all Gas pipeline companies acting in the capacity of a transporter, transporting Gas for Seller or Buyer upstream or
downstream, respectively, of the Delivery Point. 
 “Tribunal” has the meaning ascribed to the term in Section XIII.B. 
  

	B.	Interpretation 

  

	 	1.	Headings. The topical headings used in this Agreement are for convenience only and shall not be construed as having any substantive significance or as indicating that all of
the provisions of this Agreement relating to any topic are to be found in any particular Article or that an Article relates only to the topical heading. 

  

	 	2.	Singular and Plural. Reference to the singular includes a reference to the plural and vice versa. 

  

	 	3.	Gender. Reference to any gender includes a reference to all other genders. 

  

	 	4.	Article. Unless otherwise provided, reference to any Article, Section or Exhibit means an Article, Section or Exhibit of this Agreement. 

  

	 	5.	Include. The words “include” and “including” shall mean include or including without limiting the generality of the description preceding such term and
are used in an illustrative sense and not a limiting sense. 

  

	 	6.	Time Periods. References to “day,” “month,” “quarter” and “year” shall, unless otherwise stated or defined, mean a day, month, quarter
and year of the Gregorian calendar, respectively. For the avoidance of doubt, a “day” shall commence at 24:00 midnight. 

  

	 	7.	Currency. References to United States dollars shall be a reference to the lawful currency from time to time of the United States of America. 

  

 7 

	 	8.	Facilities. References to either the Sabine Pass LNG Terminal, the Creole Trail LNG Terminal, the Cheniere Sabine Pass Pipeline or the Cheniere Creole Trail Pipeline shall be
a reference to such facilities as modified from time to time. 

 ARTICLE II 
 TERM 
  

	A.	General. Subject to the terms and conditions of this Agreement, the term of this Agreement (“Term”) shall consist of the Initial Term and, if applicable, any
Extension Term. 

  

	B.	Initial Term. The initial term of this Agreement (“Initial Term”) shall commence on the Effective Date and shall continue in full force and effect until the
expiration of ten (10) years from the Commercial Start Date, unless terminated earlier in accordance with this Agreement. Seller shall give notice to Buyer of the Commercial Start Date no later than five (5) days following the later of the
date of commencement of: (a) commercial operations of the Sabine Pass LNG Terminal, (b) commercial operations of the Cheniere Creole Trail Pipeline, or (c) the commercial delivery of Gas from the Sabine Pass LNG Terminal to the
Cheniere Creole Trail Pipeline. 

  

	C.	Extension Terms. This Agreement shall extend for a five (5) year period (“Extension Term”) immediately following the expiration of the Initial Term and for a
second five (5) year Extension Term immediately following the expiration of the first Extension Term, provided that either Buyer or Seller may terminate this Agreement effective at the expiration of the then-current Term by providing written
notice to the other Party at least one-hundred twenty (120) days prior to the expiration of the then-current Term. 

 ARTICLE III 
 QUANTITY 
  

	A.	Sale and Purchase Obligations Generally. 

  

	 	1.	Seller’s Obligation. Subject to the terms and conditions of this Agreement, Seller shall make available to Buyer, for purchase at the Delivery Point(s) on each Gas Day
beginning with the Commercial Start Date, an aggregate volume of Gas equal to the Adjusted Daily Contract Quantity. 

  

	 	2.	Buyer’s Obligation. Subject to the terms and conditions of this Agreement, Buyer shall purchase from Seller at the Delivery Point(s) on each Gas Day beginning with the
Commercial Start Date an aggregate volume of Gas equal to the Adjusted Daily Contract Quantity. In this regard, Buyer covenants that it is purchasing Gas principally for resale to its customers and not for consumption as an end-user.

  

	B.	Determination of Daily Contract Quantity. 

  

	 	1.	Commencing on the Commercial Start Date, the daily contracted quantity to be purchased and sold hereunder (the “Daily Contract Quantity” or “DCQ”) shall be zero
(0) MMBtu per Gas Day. 

  

 8 

	 	2.	If Seller enters into one or more Long-Term LNG Supply Agreements before or during the Term, the Parties acknowledge that the DCQ shall from time to time be increased in accordance
with Section III.B.3. 

  

	 	a.	If Seller enters into a Long-Term LNG Supply Agreement and at the time of execution of such agreement the DCQ is less than the Maximum DCQ, Seller shall allocate, by issuing to
Buyer an Increase Notice, to Seller’s Gas supply obligations under this Agreement not less than forty percent (40%) of the LNG supply to which Seller is entitled under such Long-Term LNG Supply Agreement until the DCQ equals one hundred
thousand (100,000) MMBtu per Gas Day, and thereafter not less than twenty percent (20%) of the LNG supply to which Seller is entitled under such Long-Term LNG Supply Agreement, up to the Maximum DCQ. 

  

	 	b.	On or before March 1 of each calendar year, Seller shall provide to Buyer a certificate, executed by an officer of Seller, stating that Seller has reviewed its and its
Affiliates’ LNG supply agreements and that Seller has allocated to Seller’s Gas supply obligations under this Agreement the proper percentage of supply of all Long-Term LNG Supply Agreements. 

  

	 	c.	Seller shall provide written notice to Buyer within five (5) days of the Effective Date of all Paired Contracts then executed. After the Effective Date and during any time that
the DCQ is less than the Maximum DCQ, Seller shall provide written notice to Buyer no later than thirty (30) days after Seller’s execution of any LNG supply agreement that constitutes, or will constitute, a Paired Contract, with such
written notice (subject to any confidentiality limitations) identifying the volume of such LNG supply agreement. 

  

	 	3.	Seller shall increase the DCQ by providing to Buyer a written notice of such increase in the DCQ (the “Increase Notice”), as follows: 

  

	 	a.	An Increase Notice shall be in substantially the same form as set forth in Exhibit B attached hereto and shall indicate the increased DCQ, the calendar month during which the
increased DCQ shall first be effective, and the duration of such increase in the DCQ; 

  

	 	b.	Seller shall provide the Increase Notice to Buyer at least ninety (90) days in advance of the calendar month during which the increased DCQ shall first be effective, such
effective date to be the first day of such calendar month; 

  

	 	c.	The duration of the increase in DCQ pursuant to an Increase Notice shall not exceed the remaining Term. At least one hundred eighty (180) days prior to the end of the Term,
Buyer may request that Seller provide a reconciliation of which Increase Notices would remain in effect if the then-current Term were extended pursuant to Section II.C; 

  

 9 

	 	d.	The first Increase Notice shall be for at least twenty thousand (20,000) MMBtu per Gas Day; and 

  

	 	e.	At the time Seller issues an Increase Notice, if Buyer’s Cumulative Interruption Account is greater than $1.0 million, Buyer’s Cumulative Interruption Account shall revert
to zero unless Buyer provides written notice to Seller within thirty (30) days of the date of such Increase Notice that Buyer does not accept such Increase Notice. In the event Buyer does not accept such Increase Notice, the Buyer’s
Cumulative Interruption Account shall remain unaffected and Seller shall have no obligation to deliver to Buyer Gas pursuant to such Increase Notice. 

  

	 	4.	If, as of October 31, 2010, the DCQ determined pursuant to all Increase Notices is less than the Maximum DCQ, then either Buyer or Seller may elect to reduce the Maximum DCQ
for the remaining Term to the DCQ in effect as of October 31, 2010, as follows. Either Party may elect to reduce the Maximum DCQ by providing written notice to the other Party between October 31, 2010 and December 31, 2010; provided
that if, prior to Buyer notifying Seller of any such reduction, Seller delivers one or more Increase Notices increasing the DCQ to the Maximum DCQ, then Buyer may not subsequently reduce the Maximum DCQ. 

  

	 	5.	During any period in which the DCQ is less than the Maximum DCQ, Seller shall provide Buyer once each quarter with Seller’s non-binding estimation of the likelihood that one or
more additional Increase Notices will be provided hereunder during the next quarter. 

  

	C.	Determination of Adjusted Daily Contract Quantity. 

  

	 	1.	For each delivery month, the “Adjusted Daily Contract Quantity” or “ADCQ” shall be calculated by subtracting from the DCQ for each Gas Day:

  

	 	a.	the quantity of Gas which Buyer is unable to receive because of an event of Force Majeure affecting either Seller or Buyer; 

  

	 	b.	the quantity of Gas which Seller is unable to deliver due to an Interruption of LNG Supply notified pursuant to Section III.C.2; 

  

	 	c.	the quantity of Gas which Seller is unable to deliver due to Scheduled Maintenance notified pursuant to Section III.C.3.; and 

  

	 	d.	the quantity of Gas approximately equal in value, based on the closing price per MMBtu of Gas on the NYMEX Henry Hub natural gas futures contract for the delivery month on the date
of Seller’s Aggregate Exposure Notice, to the amount by which the anticipated exposure as of the Payment Date in the succeeding delivery month exceeds the Guarantee Limitation Amount, provided that the DCQ shall not be adjusted downward if
Buyer reduces the Aggregate Exposure below the Guarantee Limitation Amount at least two (2) Business Days prior to Bid Week for the delivery month. 

  

 10 

	 	2.	If Seller anticipates that Seller will be unable to deliver Gas to Buyer on any Gas Day for the following month due to an Interruption of LNG Supply, Seller shall notify Buyer at
least two (2) Business Days prior to the Bid Week for the delivery month of the estimated amount of the Interruption of LNG Supply. On the basis of such estimated amount, Seller shall set forth in such notice the ADCQ for each Gas Day for the
following month. 

  

	 	3.	Seller shall provide written notice to Buyer on the Commercial Start Date and no later than sixty (60) days before January 1 of each calendar year thereafter an estimate
of the dates scheduled for maintenance at the Sabine Pass LNG Terminal and the Cheniere Creole Trail Pipeline for the forthcoming calendar year (“Scheduled Maintenance”). Seller shall provide written notice no later than ten (10) days
prior to the first day of each calendar quarter (January 1, April 1, July 1 and October 1) of the updated schedule for Scheduled Maintenance for the remainder of such calendar year. If such estimated dates for Scheduled
Maintenance change, Seller shall notify Buyer within five (5) days of such changed dates. No later than two (2) Business Days prior to Bid Week for each delivery month, Seller shall notify Buyer of any volume of Gas that Seller will not be
able to deliver to Buyer for such delivery month due to Scheduled Maintenance. 

  

	D.	Damages for Failure to Deliver or Receive Gas. 

  

	 	1.	In the event that Seller fails to deliver the ADCQ to Buyer on one or more Gas Days during a delivery month, Buyer shall calculate for each day of such delivery month (i) the
difference, if any, between the purchase price paid by Buyer utilizing the Cover Standard and the Contract Price, adjusted for commercially reasonable differences in transportation costs to or from the Delivery Point(s), multiplied by the difference
between the ADCQ and the quantity actually delivered by Seller during such Gas Day; or (ii) in the event that Buyer has used commercially reasonable efforts to replace the Gas, and no such replacement is available, any difference between the
Contract Price and the Spot Price, adjusted for such transportation to the applicable Delivery Point, multiplied by the difference between the ADCQ and the quantity actually delivered by Seller and received by Buyer during such Gas Day. In such
calculation, Buyer shall net out the losses and gains from such purchases of cover Gas. At the end of such delivery month, Buyer shall provide Seller with the results of such calculation. This amount, if positive, shall be the “Seller’s
Non-Performance Payment”, which (except as provided in Section III.D.2.) Seller shall pay to Buyer. 

  

	 	2.	Without prejudice and subject to Article XI, if Seller is unable to deliver the ADCQ to Buyer on any Gas Day due to an Interruption of LNG Supply of which Seller has not notified
Buyer pursuant to Section III.C.2 and such inability lasts for a period of less than seventy-two (72) consecutive hours, Seller shall pay Seller’s Non-Performance Payment to Buyer. If Seller is unable to deliver the ADCQ to Buyer on any
Gas Day due to such an Interruption of LNG Supply for a period lasting seventy-two (72) consecutive hours or longer, then: 

  

	 	a.	Seller shall notify Buyer of such inability as soon as possible; 

  

 11 

	 	b.	Seller shall pay to Buyer an amount equal to the lesser of (i) the Seller’s Non-Performance Payment and (ii) $0.50 per MMBtu multiplied by the deficiency quantity.
The “deficiency quantity” is the difference between the total volume of Gas that would have been delivered during the month at the ADCQ and the quantity actually delivered by Seller. The Seller’s Cumulative Interruption Account shall
be increased by the amount of such payment. Buyer may at any time elect to reduce the Seller’s Cumulative Interruption Account balance to zero by paying to Seller the balance of the Seller’s Cumulative Interruption Account pursuant to
Article IX.; provided that Buyer’s Cumulative Interruption Account shall not be increased by any amounts paid by Buyer pursuant to this sentence; and 

  

	 	c.	Buyer’s Cumulative Interruption Account shall be increased by the difference, if any, between Seller’s Non-Performance Payment and the amount actually paid by Seller
pursuant to Section III.D.2.b. Seller may at any time elect to reduce the Buyer’s Cumulative Interruption Account balance to zero by paying to Buyer the balance of the Buyer’s Cumulative Interruption Account pursuant to Article IX;
provided that Seller’s Cumulative Interruption Account shall not be increased by any amounts paid by Seller pursuant to this sentence. 

  

	 	3.	In the event that Buyer fails to receive the ADCQ from Seller on any one or more Gas Days during a delivery month, then Seller shall calculate for each day of such delivery month
(i) the difference, if any, between the Contract Price and the price received by Seller utilizing the Cover Standard for the resale of such Gas, adjusted for commercially reasonable differences in transportation costs to or from the Delivery
Point(s), multiplied by the difference between the ADCQ and the quantity actually taken by Buyer during such Gas Day; or (ii) in the event that Seller has used commercially reasonable efforts to sell the Gas to a third party, and no such sale
is available, any difference between the Contract Price and the Spot Price, adjusted for such transportation to the applicable Delivery Point, multiplied by the difference between the ADCQ and the quantity actually delivered by Seller and received
by Buyer during such Gas Day. In such calculation, Seller shall net out the losses and gains from such resale of Gas. At the end of such delivery month, Seller shall provide Buyer with the results of such calculation. This amount, if positive, shall
be added to Buyer’s monthly invoice and paid to Seller pursuant to Article IX. 

  

	 	4.	For avoidance of doubt, neither Party shall have liability to the other for failure to deliver or receive Gas due to an event of Force Majeure. Seller shall have no liability to
Buyer for failure to deliver Gas: 

  

	 	a.	due to an Interruption of LNG Supply provided that Seller notifies Buyer of an Interruption of LNG Supply in accordance with Section III.C.2; or 

  

 12 

	 	b.	due to Scheduled Maintenance provided that Seller notifies Buyer of Scheduled Maintenance in accordance with Section III.C.3. 

  

	 	5.	Imbalance Charges shall not be recovered under this Section III.D, but Seller and/or Buyer shall be responsible for Imbalance Charges, if any, as provided in Section VI.D.

  

	E.	Any amount payable by a Party pursuant to Section III.D shall be treated as actual, direct damages and shall not be treated as consequential damages or as loss of income or profits
under Section XII.H. 

  

	F.	Any amount payable pursuant to Section III.D shall be credited as an offset, in the case of amounts payable by Seller, or itemized on an invoice separately, in the case of amounts
payable by Buyer, pursuant to the provisions of Article IX. 

 ARTICLE IV 
 PRICE 
  

	A.	Price of Gas. 

  

	 	1.	The price of Gas sold and purchased with respect to any month (the “Contract Price”) shall be ninety-six percent (96%) of the price in dollars per MMBtu for the NYMEX
Henry Hub Natural Gas futures contract for Gas to be delivered during such month, such price to be based upon the final settlement price on the last trading day for the futures contracts for such month, plus ten cents ($0.10) per MMBtu.

  

	 	2.	If the NYMEX Henry Hub Natural Gas futures contract settlement prices cease to be published for any reason, or the data is so changed in the basis of calculation or quantity or type
of commodity included therein or otherwise as to affect materially the validity of the index over time, the Parties shall select a comparable index to be used in its place that maintains the intent and economic effect of the original index.

  

	B.	Taxes. 

  

	 	1.	The prices established pursuant to this Article IV are inclusive of all Taxes levied on Seller or for which Seller is responsible. 

  

	 	2.	 Seller shall pay or cause to be paid all taxes, fees, levies, penalties, licenses or charges imposed by any governmental authority (“Taxes”) on Seller on
or with respect to the Gas prior to the Delivery Point. Buyer shall pay or cause to be paid all Taxes imposed by any governmental authority on Buyer on or with respect to the Gas at and after the Delivery Point. If a Party is required to collect,
remit or pay Taxes that are the other Party’s responsibility hereunder, the Party responsible for such Taxes shall promptly reimburse the other Party for such Taxes. Any Party entitled to an exemption from any such Taxes or charges shall
furnish the 

  

 13 

	 	 
other Party any necessary documentation thereof on or before the date of delivery of the Gas. 

  

	 	3.	Buyer shall provide Seller with information as may be required to allow Seller to properly file all required federal, state, and local tax reports and other regulatory filings.

 ARTICLE V 
 DELIVERY POINT 
  

	A.	The delivery point(s) shall be the interconnects between the Cheniere Creole Trail Pipeline and any Principal Pipeline or other pipeline interconnecting with the Cheniere Creole
Trail Pipeline (each, an “Interconnect Pipeline”) as nominated by Buyer (the “Delivery Point(s)”) 

  

	B.	Seller shall have the right at the time that Buyer makes its nomination for the upcoming Gas Day pursuant to Section VI.B. to move any Delivery Point from the physical
interconnection between the Interconnect Pipeline and the Cheniere Creole Trail Pipeline to the Interconnect Pipeline’s local pooling point, if applicable; provided, however, if such pooling point(s) are allocated or curtailed by an
Interconnect Pipeline, Seller shall use commercially reasonable efforts to revert to the Delivery Point(s) nominated by Buyer. 

 ARTICLE VI 
 TRANSPORTATION 
  

	A.	Seller shall have sole responsibility for transporting the Gas to the Delivery Point(s), subject to the following requirements: 

  

	 	1.	The arithmetic sum of the delivery quantity nominated for each Delivery Point on any Gas Day shall not exceed the ADCQ; and 

  

	 	2.	 Buyer’s nomination to Seller for delivery at any Interconnect Pipeline shall not exceed Buyer’s pro-rata portion of Seller’s delivery capacity to
such pipeline. “Buyer’s pro-rata portion” means the proportion that the ADCQ on any particular Gas Day bears to Seller’s firm capacity on the Cheniere Creole Trail Pipeline. “Seller’s delivery capacity to such
pipeline” means the product of: (i) Seller’s share (as a proportion) of firm capacity rights on the Cheniere Creole Trail Pipeline; and (ii) the firm delivery capacity of the Cheniere Creole Trail Pipeline to the Interconnect
Pipeline. Seller shall provide Buyer with written notice of “Buyer’s pro-rata portion” and “Seller’s delivery capacity to such pipeline” before the nomination cycle for the Gas Day beginning on the Commercial Start
Date. To the extent “Buyer’s pro-rata portion” or “Seller’s delivery capacity to such pipeline” changes, Seller shall provide Buyer with written notice of such change in advance of the first nomination cycle during
which such change may effect Buyer’s access to Delivery Point(s). If Buyer’s requested delivery quantity for any Delivery Point exceeds Buyer’s pro-rata portion of Seller’s delivery capacity at such pipeline as provided in
Seller’s notices to Buyer, Seller shall have no 

  

 14 

	 	 
obligation to deliver the excess quantity and Buyer shall be deemed to have failed to receive such excess quantity. 

  

	B.	Buyer shall have sole responsibility for transporting the Gas from and after the Delivery Point(s). Buyer shall orally communicate to Seller’s pipeline scheduling
representative (i) the requested Delivery Point(s) and (ii) the requested delivery quantity for the Gas Day at each Delivery Point no later than 8:30 AM on the day prior to the Gas Day for deliver of such Gas and Buyer shall confirm such
nomination request in writing no later than forty-five (45) minutes later. Seller shall use commercially reasonable efforts to accommodate Buyer’s intraday changes to such nominations. 

  

	C.	In addition to meeting the obligations set forth in Section VI.A.2, the Parties shall coordinate their nomination activities, giving sufficient time to meet the deadlines of the
affected Transporter. Should either Party become aware that actual deliveries at the Delivery Point(s) are greater or lesser than the nominated delivery quantity, such Party shall promptly notify the other Party. The Parties expressly agree that any
allocation, reduction, or curtailment of capacity at a Delivery Point shall constitute an event of Force Majeure. Seller shall use commercially reasonable efforts to increase, by the amount of the allocation, reduction, or curtailment, the delivery
quantities at other Delivery Point(s). 

  

	D.	The Parties shall use commercially reasonable efforts to avoid imposition of any Imbalance Charges. If Buyer or Seller receives an invoice from a Transporter that includes Imbalance
Charges, the Parties shall determine the validity as well as the cause of such Imbalance Charges. If the Imbalance Charges were incurred as a result of Buyer’s receipt of quantities of Gas greater than or less than the Adjusted Daily Contract
Quantity, then Buyer shall pay for such Imbalance Charges or reimburse Seller for such Imbalance Charges paid by Seller. If the Imbalance Charges were incurred as a result of Seller’s delivery of quantities of Gas greater than or less than the
Adjusted Daily Contract Quantity, then Seller shall pay for such Imbalance Charges or reimburse Buyer for such Imbalance Charges paid by Buyer. 

 ARTICLE VII 
 QUALITY AND MEASUREMENT 
  

	A.	Quality. Deliveries of Gas by Seller to Buyer at the Delivery Point(s) pursuant to this Agreement shall meet the pressure, quality and heat content requirements of the
Principal Pipelines as established by the FERC Gas Tariffs for such pipelines, as may be in effect from time to time (“Gas Quality Standard”). 

  

	 	1.	It is the obligation of Seller to notify Buyer if Gas to be delivered by Seller to Buyer will not meet the Gas Quality Standard or if Seller has reason to believe that the Gas will
not meet the Gas Quality Standard. 

  

	 	2.	 Buyer shall have no obligation to accept, purchase and pay for Gas that does not meet the Gas Quality Standard. If Buyer knowingly accepts Gas that Seller notifies
Buyer in writing fails to meet the Gas Quality Standard, Buyer shall be obligated to pay for such Gas, Seller shall have no liability for Claims arising 

  

 15 

	 	 
from such Gas and as to such Gas, Buyer hereby waives all rights under the New York Uniform Commercial Code for acceptance of non-conforming goods.

  

	B.	Measurement. All measurements of Gas delivered and sold hereunder shall be in accordance with the established procedures, as they may be in effect from time to time, of the
receiving pipeline at the Delivery Point(s). 

 ARTICLE VIII 
 TERMINATION 
  

	A.	Seller may terminate this Agreement upon thirty (30) days written notice to Buyer in the event of any of the following: 

  

	 	1.	Seller has not received and accepted, in its reasonable discretion, all Government Approvals necessary to perform its obligations under this Agreement by June 30, 2008;
provided, however, that Seller shall have exercised reasonable efforts to obtain all such Government Approvals; 

  

	 	2.	the Commercial Start Date has not occurred by June 30, 2010; or 

  

	 	3.	Seller has not issued the first Increase Notice by October 31, 2010; or 

  

	 	4.	Seller’s Cumulative Interruption Account exceeds fifteen million dollars ($15,000,000). If Seller elects not to terminate this Agreement within the notice period of this
Section VIII.A., such right shall expire, and the amount of Seller’s Cumulative Interruption Account shall be set to zero ($0.00). 

  

	B.	Buyer may terminate this Agreement upon thirty (30) days written notice to Seller in the event of either of the following: 

  

	 	1.	the Commercial Start Date has not occurred by June 30, 2010; or 

  

	 	2.	Seller has not issued the first Increase Notice by October 31, 2010; or 

  

	 	3.	Buyer’s Cumulative Interruption Account exceeds fifteen million dollars ($15,000,000). If Buyer elects not to terminate this Agreement within the notice period of this Section
VIII.B., such right shall expire, and the amount of Buyer’s Cumulative Interruption Account shall be set to zero ($0.00). 

 ARTICLE IX 
 BILLING, PAYMENT AND AUDIT 
  

	A.	 Seller shall invoice Buyer for Gas delivered and received in the preceding month and for any other applicable charges, providing supporting documentation acceptable
in industry practice to support the amount charged. Seller shall calculate the invoice amount for Gas delivered based on a Gas price rounded to the fourth decimal place. If the actual quantity delivered is not known by the billing date, billing will
be prepared based on the estimated Adjusted Daily Contract Quantity for such month. The invoiced quantity will then be 

  

 16 

	 	 
adjusted to the actual quantity on the following month’s billing or as soon thereafter as actual delivery information is available.

  

	B.	Buyer shall remit the amount due under Section IX.A., in immediately available funds, on or before the Payment Date; provided that if the Payment Date is not a Business Day, payment
is due on the next Business Day following that date. In the event any payments are due Buyer hereunder, payment to Buyer shall be made in accordance with this Section IX.B. 

  

	C.	The invoiced Party shall pay the full amount of any disputed invoice without any deduction or set-off (except as to any deduction or set-off otherwise allowed under this Agreement),
provided that in the case of an obvious error in computation, the invoiced Party shall pay the correct amount disregarding such error. If the invoiced Party disputes the amount due, it must provide supporting documentation acceptable in industry
practice to support the amount paid or disputed. The Parties will endeavor to resolve any Dispute of an invoice within thirty (30) days after notice of the disputed invoice is given. If it is ultimately determined that all or a portion of the
disputed amount was incorrectly invoiced and paid by Buyer to Seller, Seller shall pay Buyer that amount within two Business Days of such determination, along with interest (as determined in Section IX.D). from and including the original payment
date to but excluding the date payment is made. In the event the Parties are unable to resolve such Dispute within such period, either Party may refer the Dispute to arbitration under Article XIII. 

  

	D.	If the invoiced Party fails to remit the full amount payable when due, interest on the unpaid portion shall accrue from the date due until the date of payment at a rate equal to the
lower of (i) the then-effective prime rate of interest per annum published under “Money Rates” by The Wall Street Journal, plus two percentage points; or (ii) the maximum applicable lawful interest rate. 

 

	E.	A Party shall have the right, at its own expense, upon reasonable notice and at reasonable times, to examine, audit and to obtain copies of the relevant portion of the books,
records, and telephone recordings of the other Party only to the extent reasonably necessary to verify the accuracy of any statement, charge, payment, or computation made under this Agreement. This right to examine, audit, and to obtain copies and
recordings shall not be available with respect to proprietary information not directly relevant to this Agreement. All invoices and billings shall be conclusively presumed final and accurate and all associated claims for under- or overpayments shall
be deemed waived unless such invoices or billings are objected to in writing, with adequate explanation and/or documentation, within two years after the month of Gas delivery. All retroactive adjustments under Article IX shall be paid in full by the
Party owing payment within thirty days after receipt of notice and substantiation of such inaccuracy. 

  

	F.	 The Parties shall net all amounts due and owing (including amounts owed from Seller to Buyer pursuant to Section III.D), and/or past due, arising under the
Agreement such that the Party owing the greater amount shall make a single payment of the net amount to the other Party in accordance with Article IX. If the Parties have executed a separate netting 

  

 17 

	 	 
agreement, the terms and conditions therein shall prevail to the extent inconsistent herewith. 

 ARTICLE X 
 TITLE, WARRANTY AND
INDEMNITY 
  

	A.	Title to the Gas shall pass from Seller to Buyer at the Delivery Point(s). Seller shall have responsibility for and assume any liability with respect to the Gas prior to its
delivery to Buyer at the Delivery Point(s). Buyer shall have responsibility for and shall assume any liability with respect to said Gas at and after its delivery to Buyer at the Delivery Point(s). 

  

	B.	Seller warrants that it will have the right to convey and will transfer good and merchantable title to all Gas sold hereunder and delivered by it to Buyer, free and clear of all
liens, encumbrances, and claims. EXCEPT AS PROVIDED IN THIS SECTION X.B ALL OTHER WARRANTIES, EXPRESS OR IMPLIED, INCLUDING ANY WARRANTY OF MERCHANTABILITY OR OF FITNESS FOR ANY PARTICULAR PURPOSE, ARE DISCLAIMED. 

  

	C.	Seller agrees to indemnify Buyer and save it harmless from all losses, liabilities or claims including reasonable attorneys’ fees and costs of court (“Claims”), from
any and all Persons, arising from or out of claims of title, personal injury or property damage from said Gas or other charges thereon which attach before title passes to Buyer. Buyer agrees to indemnify Seller and save it harmless from all Claims,
from any and all Persons, arising from or out of claims regarding payment, personal injury or property damage from said Gas or other charges thereon which attach after title passes to Buyer. 

  

	D.	Notwithstanding the other provisions of this Article X and except in the case where Buyer knowingly accepts Gas that does not meet the Gas Quality Standard, as between Seller and
Buyer, Seller will be liable for all Claims to the extent that such arise from the failure of Gas delivered by Seller to meet the Gas Quality Standard. 

 ARTICLE XI 
 FORCE MAJEURE 
  

	A.	Excuse Due to Force Majeure. Neither Seller nor Buyer shall be liable for any delay or failure in performance hereunder if and to the extent (i) such delay or failure in
performance (except for the performance of any payment obligation) is a result of Force Majeure, and (ii) the Excused Party satisfies its obligations under this Article XI. The Party so excused shall be called the “Excused Party.”

  

	B.	 Events of Force Majeure. “Force Majeure” shall mean any act, event or circumstance, whether of the kind described herein or otherwise, that is not
reasonably within the control of, does not result from the fault or negligence of, and would not have been avoided or overcome by the exercise of reasonable diligence by, the Party claiming Force Majeure, such Party having observed a standard of
conduct that is consistent with a reasonable and prudent operator, and that prevents or delays in whole or in part such Party’s performance of any one or more of its obligations under this Agreement. It may 

  

 18 

	 	 
include circumstances of the following kind, provided that such circumstances satisfy the definition of Force Majeure set forth above:

  

	 	1.	physical events such as acts of God, landslides, lightning, atmospheric disturbance, earthquakes, fires, storms or storm warnings, such as hurricanes, tornados, floods, washouts,
explosions, and weather related events, including events that impede the unloading of LNG or impede the delivery of regasified LNG to the Delivery Point(s) or the receipt and transportation of Gas away from the Delivery Point(s);

  

	 	2.	storms, storm warnings, hurricanes, or other weather related events that delay or impede the entry of an LNG Tanker into the Gulf of Mexico, or the transit of an LNG Tanker within
the Gulf of Mexico to an LNG Terminal; 

  

	 	3.	acts of others such as strikes, lockouts or other industrial disturbances, riots, sabotage, insurrections, wars, invasions, embargos, terrorism or threat thereof, blockade, acts of
public enemies or civil disturbances; 

  

	 	4.	acts of governmental authorities having jurisdiction, including the issuance or promulgation of any court order, law, statute, ordinance, regulation, or policy having the effect of
law, the effect of which would prevent, delay or make unlawful a Party’s performance hereunder, or would require such Party to take measures which are unreasonable in the circumstances; 

  

	 	5.	breakdown, accident to, or destruction of facilities or equipment or lines of pipe (including the LNG Terminals), except when such breakdown or destruction is due to normal wear and
tear, failure to properly maintain such facilities or equipment or to adequately stock spare repair parts; 

  

	 	6.	inability to obtain, or suspension, termination, adverse modification, interruption, or inability to renew, any servitude, right of way, easement, permit, license, consent,
authorization, or approval of any governmental authority; 

  

	 	7.	events affecting the ability of the LNG Terminals to offload, store, and regasify LNG, including unplanned curtailments and unplanned maintenance and governmental actions such as
are necessary for compliance with any court order, law, status, ordinance, regulation or policy having the effect of law promulgated by a governmental authority having jurisdiction; and 

  

	 	8.	any other event of Force Majeure that excuses the performance of the Person providing LNG terminalling services to Seller at the LNG Terminals, if and to the extent that it is of a
kind or character that, if it had happened to a Party, would have come within the definition of Force Majeure under this Article XI. 

  

	 	9.	 For greater certainty, an act, event or circumstance which primarily affects a third party (including an affiliate of a Party) which prevents, impedes or delays
Seller’s or Buyer’s performance hereunder, shall constitute Force Majeure hereunder as to Seller or Buyer (as appropriate) if and to the extent that it is of a kind or character 

  

 19 

	 	 
that, if it had happened to a Party, would have come within the definition of Force Majeure under this Article XI. 

  

	C.	Events Not Constituting Force Majeure. Notwithstanding the other provisions of this Article XI, Force Majeure shall not include: 

  

	 	1.	breakdown of an LNG Tanker (whether or not otherwise constituting a Force Majeure) prior to it reaching the pilot boarding station at the LNG Terminals; 

  

	 	2.	storms, storm warnings, hurricanes, and other weather related events that delay or impede the transit of an LNG Tanker that is not excused pursuant to Section XI.B.2;

  

	 	3.	any event (whether or not otherwise constituting a Force Majeure) that affects the liquefaction facilities or country from which Seller sources LNG, including the loss of
Seller’s LNG supply or depletion of reserves of gas used to produce such LNG supply; 

  

	 	4.	the non-availability or lack of funds or failure to pay money when due; 

  

	 	5.	the withdrawal, denial or expiration of or failure to obtain any governmental approval of any national or local governmental authority, agency or entity acting for or on behalf
thereof, caused by the affected Person’s (i) actions, including a violation of or breach of the terms and conditions of any existing governmental approval or other requirement of law, or (ii) inactions, including the failure to apply
for or follow the necessary procedures to obtain any governmental approval or request, acquire or take all necessary actions to obtain the renewal or reissuance of the same, in either event, only if the affected Person knew or should have known,
after due inquiry and the exercise of endeavors expected by a reasonable and prudent operator, that such action or inaction, as the case may be, would have caused the withdrawal, denial or expiration of, non-renewal or non-issuance of any
governmental approval; or 

  

	 	6.	economic hardship, including Seller’s ability to sell Gas at a higher or more advantageous price than the price for Gas sold under this Agreement, or Buyer’s ability to
purchase Gas at a lower or more advantageous price than the price for Gas purchased under this Agreement. 

  

	D.	Notice; Resumption of Normal Performance. 

  

	 	1.	 Immediately upon the occurrence of an event of Force Majeure that may delay or has delayed or prevented, or may or will delay or prevent, the performance by the
Excused Party of any of its obligations hereunder, the Excused Party shall give notice thereof (promptly confirmed in writing if originally given orally, but in no event later than three (3) Business Days after the occurrence of such event) to
the other Party describing such event and stating each of such Party’s obligations hereunder which such Party may, has been or will be delayed or prevented from performing, and (either in the original or in supplemental notices) stating:
(i) its 

  

 20 

	 	 
good faith estimate of the likely duration of the Force Majeure event and of the period during which performance may be suspended or reduced, including to
the extent known or ascertainable, the estimated extent of such reduction in performance; and (ii) the particulars of the program to be implemented and any corrective measures already undertaken to ensure full resumption of normal performance
hereunder. The Excused Party shall provide, from time to time as warranted, updates to the notices provided in this Section XI.D.1. 

  

	 	2.	In order to ensure resumption of normal performance of this Agreement within the shortest practicable time, the Excused Party shall take all measures to this end which are
commercially reasonable in the circumstances, taking into account the consequences resulting from such event of Force Majeure. To the extent that the Excused Party fails to use commercially reasonable efforts to overcome or mitigate the effects of
such events of Force Majeure, it shall not be excused for any delay or failure in performance that would have been avoided by using such commercially reasonable efforts. Prior to resumption of normal performance, the Parties shall continue to
perform their obligations under this Agreement to the extent not excused or prevented by such event of Force Majeure. 

  

	 	3.	Upon request of the non-excused Party given no sooner than the second Business Day after the Excused Party’s notice of Force Majeure, the Excused Party shall forthwith use all
reasonable efforts to give or procure access for representatives of the non-excused Party to examine the scene of the event which gave rise to the claim of Force Majeure, and such access shall be at the expense of the non-excused Party.

  

	E.	Seller’s Rights Upon Buyer’s Force Majeure. If Buyer has a claim of Force Majeure and is rendered wholly or partially unable to accept deliveries of Gas under this
Agreement, Seller may enter into gas sales agreements with third persons for the quantity of Gas Buyer would have been obligated to take hereunder except for the relevant Force Majeure events, but for a term no longer than the expected duration of
the Force Majeure as contained in the notice delivered to Seller. Upon resumption of Buyer’s ability to perform under this Agreement, Seller shall continue to be excused for failure to deliver Gas to Buyer to the extent resulting from
Seller’s obligations under such third party agreements until such third party agreements are required to be terminated in accordance with the following: if the estimated duration of Force Majeure, as stated in the notice provided by Buyer
pursuant to Section IX.D.1 is less than one hundred eighty (180) days, Seller shall use reasonable efforts, but shall not be required, to terminate such sales prior to the end of the period stated in the notice if the actual period of Force
Majeure ends prior to such date. In the event that the estimated duration of Force Majeure, as stated in the notice provided by Buyer pursuant to Section IX.D.1 is greater than one hundred eighty (180) days, Seller shall terminate such sales on
no less than ninety (90) days notice from Buyer of the end of the period of Force Majeure, and shall use reasonable efforts, but shall not be required, to terminate such sales on such lesser notice as Buyer may provide. The ninety (90) day
notice may not be given by Buyer to Seller prior to ninety (90) days from the start of the Force Majeure event, unless agreed to by Seller. 

  

 21 

	F.	Settlement of Industrial Disturbances. Settlement of strikes, lockouts or other industrial disturbances shall be entirely within the discretion of the Party experiencing such
situations and nothing herein shall require such Party to settle industrial disputes by yielding to demands made on it when it considers such action inadvisable. 

  

	G.	Extended Force Majeure. If a Force Majeure event affecting the total DCQ lasts for twenty-four (24) consecutive months and the Parties do not foresee that the Force
Majeure situation will be resolved in the foreseeable future, either Party shall have the right to terminate this Agreement by notice to the other Party. If a Force Majeure event affecting a portion of the DCQ lasts for twenty-four
(24) consecutive months and the Parties do not foresee that the Force Majeure situation will be resolved in the foreseeable future, either Party shall have the right to reduce the DCQ by a corresponding amount by notice to the other Party.

 ARTICLE XII 
 DEFAULTS AND REMEDIES 
  

	A.	In the event (each an “Event of Default”) either Party (the “Defaulting Party”) shall: 

  

	 	1.	fail to receive, in the case of Buyer, Gas in accordance with the terms of this Agreement on fifteen (15) days in a twelve-month period; 

  

	 	2.	breach a material representation or warranty if such breach is not remedied within five (5) Business Days after written notice of such breach is given to the Defaulting Party;

  

	 	3.	fail to make when due any payment required under this Agreement if such failure is not remedied within five (5) Business Days after written notice of such failure is given to
the Defaulting Party; 

  

	 	4.	make an assignment or any general arrangement for the benefit of creditors; 

  

	 	5.	file a petition or otherwise commence, authorize, or acquiesce in the commencement of a proceeding or case under any bankruptcy or similar law for the protection of creditors, or
have such petition filed or proceeding commenced against it that is not dismissed within sixty (60) days; 

  

	 	6.	otherwise become bankrupt or insolvent (however evidenced); 

  

	 	7.	be unable to pay its debts as they fall due; or 

  

	 	8.	have a receiver, provisional liquidator, conservator, custodian, trustee or other similar official appointed with respect to it or substantially all of its assets that is not
dismissed within sixty (60) days, 

 then the other Party (the “Non-Defaulting Party”) shall have the right, at
its sole election, to immediately withhold and/or suspend deliveries or payments upon two (2) days notice, in addition to any and all other remedies available hereunder. 
  

 22 

	B.	It shall also be an Event of Default, with Buyer being the Defaulting Party, if the Buyer Guarantor: 

  

	 	1.	suspends payment of its debts or is unable to pay its or their debts; 

  

	 	2.	passes a resolution, commences proceedings or has proceedings commenced against it (which are not stayed within twenty-one (21) days of service thereof on the Buyer Guarantor)
in the nature of bankruptcy or reorganization resulting from insolvency or for its liquidation or for the appointment of a receiver, trustee in bankruptcy or liquidator of its undertaking or assets; or 

  

	 	3.	enters into any composition or scheme or arrangement with its creditors, 

 unless, within ten (10) Business Days of such Event of Default, a replacement Buyer Guarantee reasonably acceptable to Seller is executed and delivered to the Seller. 
  

	C.	If an Event of Default has occurred and is continuing, the Non-Defaulting Party shall have the right, by written notice to the Defaulting Party, to designate a day, no earlier than
the day such notice is given and no later than twenty (20) days after such notice is given, as an early termination date (the “Early Termination Date”), on which date, all of the rights and obligations of each Party pursuant to this
Agreement shall terminate. 

  

	D.	The Non-Defaulting Party shall net or aggregate, as appropriate, any and all amounts owing between the Parties under this Agreement so that all such amounts are netted or aggregated
to a single liquidated amount payable by one Party to the other (the “Net Settlement Amount”). 

  

	E.	If any obligation that is to be included in any netting, aggregation or setoff pursuant to Section XII.D is unascertained, the Non-Defaulting Party may in good faith estimate that
obligation and net, aggregate or setoff, as applicable, in respect of the estimate, subject to the Non-Defaulting Party accounting to the Defaulting Party when the obligation is ascertained. Any amount not then due which is included in any netting,
aggregation or setoff pursuant to Section XII.D shall be discounted to net present value in a commercially reasonable manner determined by the Non-Defaulting Party. 

  

	F.	As soon as practicable after a liquidation, notice shall be given by the Non-Defaulting Party to the Defaulting Party of the Net Settlement Amount, and whether the Net Settlement
Amount is due to or due from the Non-Defaulting Party. The notice shall include a written statement explaining in reasonable detail the calculation of such amount, provided that failure to give such notice shall not affect the validity or
enforceability of the liquidation or give rise to any claim by the Defaulting Party against the Non-Defaulting Party. The Net Settlement Amount shall be paid by the close of business on the second Business Day following such notice, which date shall
not be earlier than the Early Termination Date. Interest on any unpaid portion of the Net Settlement Amount shall accrue from the date due until the date of payment at a rate equal to the lower of (i) the then-effective prime rate of interest
per annum published under “Money Rates” by The Wall Street Journal, plus two percentage points; or (ii) the maximum applicable lawful interest rate. 

  

 23 

	G.	The expiry or termination of this Agreement shall not: (i) relieve either Party from any obligations to the other Party incurred or arising prior to the date of such expiry or
termination; (ii) or extinguish any rights of either Party accrued in respect of periods prior to the expiry or termination of this Agreement or (iii) effect a Party’s claim for damages against the other Party on account of the other
Party’s breach or default of this Agreement. 

  

	H.	NEITHER PARTY SHALL BE LIABLE FOR CONSEQUENTIAL, INCIDENTAL, PUNITIVE, EXEMPLARY OR INDIRECT DAMAGES, LOST PROFITS OR OTHER BUSINESS INTERRUPTION DAMAGES, BY STATUTE, IN TORT OR
CONTRACT, UNDER ANY INDEMNITY PROVISION OR OTHERWISE. 

  

	I.	IT IS THE INTENT OF THE PARTIES THAT THE LIMITATIONS HEREIN IMPOSED ON REMEDIES AND THE MEASURE OF DAMAGES BE WITHOUT REGARD TO THE CAUSE OR CAUSES RELATED THERETO, INCLUDING THE
NEGLIGENCE OF ANY PARTY, WHETHER SUCH NEGLIGENCE BE SOLE, JOINT OR CONCURRENT, OR ACTIVE OR PASSIVE. WHERE REMEDIES OR DAMAGES ARE SPECIFICALLY ESTABLISHED IN THIS AGREEMENT, SUCH REMEDIES OR DAMAGES SHALL CONSTITUTE THE SOLE AND EXCLUSIVE REMEDY
FOR SUCH EVENT(S). TO THE EXTENT ANY DAMAGES REQUIRED TO BE PAID HEREUNDER ARE LIQUIDATED, THE PARTIES ACKNOWLEDGE THAT THE DAMAGES ARE DIFFICULT OR IMPOSSIBLE TO DETERMINE, OR OTHERWISE OBTAINING AN ADEQUATE REMEDY IS INCONVENIENT AND THE DAMAGES
CALCULATED HEREUNDER CONSTITUTE A REASONABLE APPROXIMATION OF THE HARM OR LOSS. 

 ARTICLE XIII 
 DISPUTE RESOLUTION 
  

	A.	Any Dispute shall be settled by arbitration administered by the American Arbitration Association (“AAA”) under its Commercial Arbitration Rules (as then in effect),
provided, however, that insofar as any of the provisions of this Article XIII are inconsistent with the Commercial Arbitration Rules, the provisions of this Article XIII shall prevail. 

  

	B.	The arbitral tribunal (“Tribunal”) shall consist of three (3) arbitrators. Each Party shall appoint one (1) arbitrator within thirty (30) days of the filing
of the arbitration, and the two arbitrators so appointed shall select the presiding arbitrator within thirty (30) days after the latter of the two arbitrators has been appointed by the Parties. If a Party fails to appoint its Party-appointed
arbitrator or if the two Party-appointed arbitrators cannot reach an agreement on the presiding arbitrator within the applicable time period, then the AAA shall serve as the appointing authority, and shall appoint the remainder of the three
arbitrators not yet appointed. All three arbitrators shall be impartial and independent. 

  

	C.	Unless otherwise expressly agreed in writing by all parties to the Dispute, the place of arbitration shall be Houston, Texas. 

  

 24 

	D.	Unless otherwise expressly agreed in writing by all parties to the Dispute, the Tribunal shall strictly apply the law governing this Agreement. Where the measure, nature, scope or
type of damages for a claim is expressly limited by the terms of this Agreement, the Tribunal shall have no discretion to award damages beyond those express limitations. 

  

	E.	The Tribunal shall conduct the arbitration as expeditiously as possible, and shall take all reasonable measures to render the award within six (6) months of the date that the
presiding arbitrator is appointed. If the award is not rendered within this (6) six month period, the Tribunal will still have jurisdiction over the Dispute. The award shall (i) be rendered in writing, (ii) state the legal grounds and
reasoning for its decision, and (iii) provide for a monetary award immediately payable in United States dollars. 

  

	F.	All notices required for any arbitration proceeding shall be deemed properly given if given in accordance with Section XV.F. The Parties further agree that service of process for
any action to enforce an arbitral award may be accomplished according to the procedures of Section XV.F, as well as any other procedure authorized by law. 

  

	G.	The Tribunal is authorized to allocate the costs of the arbitration in its award, including: (a) the fees and expenses of the arbitrators; (b) the costs of assistance
required by the Tribunal, including any experts; (c) the fees and expenses of the administrator; (d) the reasonable costs for legal representation of a successful Party, including expert fees; and (e) any such costs incurred in
connection with an application for interim or emergency relief. The costs of the arbitration proceedings, including attorneys’ fees, shall be borne in the manner determined by the Tribunal. 

  

	H.	The Tribunal shall have the discretion to award pre-award and post-award interest from the date of any default or other breach of this Agreement until the arbitral award is paid in
full. 

  

	I.	The award shall, as between the Parties, be final and entitled to all of the protections and benefits of a final judgment, e.g., res judicata (claim preclusion) and collateral
estoppel (issue preclusion), as to all claims, including compulsory counterclaims, that were or could have been presented to the arbitrators. The award shall not be reviewable by or appealable to any court; provided, however, that the award may be
corrected or interpreted pursuant to the Commercial Arbitration Rules. 

  

	J.	Any arbitration pursuant to this Article XIII (including a settlement resulting from an arbitral award, documents exchanged or produced during an arbitration proceeding, and
memorials, briefs or other documents prepared for the arbitration) shall be confidential and may not be disclosed by the Parties, their employees, officers, directors, counsel, consultants, and expert witnesses, except to the extent necessary to
enforce this Article XIII or any arbitration award, to enforce other rights of a party to a dispute resolved pursuant to this Article XIII, or as required by law; provided, however, that breach of this confidentiality provision shall not void any
settlement, or award. 

  

	K.	 Each Party shall have the right to petition any court for the issuance of any restraining order, other equitable relief or interim measure (i) prior to the
constitution of the Tribunal 

  

 25 

	 	 
(and thereafter as necessary to enforce the Tribunal’s rulings); or (ii) in the absence of the jurisdiction of the Tribunal to rule on interim
measures in a given jurisdiction. FOR PURPOSES OF THIS SECTION XIII K, EACH OF THE PARTIES IRREVOCABLY CONSENTS AND SUBMITS UNCONDITIONALLY TO THE NON-EXCLUSIVE JURISDICTION OF ANY STATE OR FEDERAL COURT OF COMPETENT JURISDICTION IN THE STATE OF
TEXAS, UNITED STATES OF AMERICA, AND IRREVOCABLY WAIVES ANY PRESENT OR FUTURE OBJECTION TO SUCH VENUE FOR SUCH PURPOSES. 

  

	L.	A Party’s breach of this Agreement shall not affect this agreement to arbitrate. Moreover, the Parties’ obligations under this arbitration provision are enforceable even
after this Agreement has terminated. The invalidity or unenforceability of any provision of this agreement to arbitrate shall not affect the validity or enforceability of the Parties’ obligation to submit their claims to binding arbitration or
the other provisions of this agreement to arbitrate. 

 ARTICLE XIV 
 CREDIT SUPPORT 
  

	A.	Generally. Each Party shall deliver to the other Party credit support according to the terms of this Article XIV. 

  

	B.	Seller Credit Support. Seller shall provide on the date of this Agreement, and cause to be maintained until the delivery of the first invoice pursuant to Article IX of this
Agreement, a Seller Guarantee in an amount equal to $5,000,000. Buyer is relying on the legal, valid, binding and enforceable nature of the Seller Guarantee as an essential inducement and consideration for entering into this Agreement.

  

	C.	Buyer Credit Support. 

  

	 	1.	Buyer shall provide on the date of this Agreement, and cause to be maintained throughout the Term, a Buyer Guarantee in an amount available to be drawn thereunder equal at any time
and from time to time to the Guarantee Limitation Amount. Seller is relying on the legal, valid, binding and enforceable nature of the Buyer Guarantee as an essential inducement and consideration for entering into this Agreement.

  

	 	2.	At any time, Buyer may elect to reduce the amount of the Aggregate Exposure by making payment to Seller of all or part of amounts invoiced prior to the Payment Date hereunder. Buyer
shall notify Seller of its intention to make payments prior to the Payment Date at least two (2) Business Days prior to Bid Week for the delivery month. 

  

 26 

 ARTICLE XV 
 MISCELLANEOUS 
  

	A.	This Agreement shall be binding upon and inure to the benefit of the successors, assigns, personal representatives, and heirs of the respective Parties hereto, and the covenants,
conditions, rights and obligations of this Agreement shall run for the Term. 

  

	B.	Either Party may assign this Agreement to a third party, including Buyer to a creditworthy third party, in whole or in part, provided that such Party obtained the prior written
consent of the non-assigning Party, which consent will not be unreasonably withheld or delayed; provided, either Party may (i) transfer, sell, pledge, encumber, or assign this Agreement or the accounts, revenues, or proceeds hereof in
connection with any financing or other financial arrangements, or (ii) transfer its interest to any parent or affiliate by assignment, merger or otherwise without the prior approval of the other Party. Upon any such assignment, transfer and
assumption, the transferor shall remain principally liable for and shall not be relieved of or discharged from any obligations hereunder. 

  

	C.	If any provision in this Agreement is determined to be invalid, void or unenforceable by any court having jurisdiction, such determination shall not invalidate, void, or make
unenforceable any other provision, agreement or covenant of this Agreement. 

  

	D.	No waiver of any breach of this Agreement shall be held to be a waiver of any other or subsequent breach. 

  

	E.	This Agreement sets forth all understandings between the Parties respecting the rights and obligations of the Parties pursuant to this Agreement, and any prior contracts,
understandings and representations, whether oral or written, relating to the rights and obligations pursuant to this Agreement are merged into and superseded by this Agreement. This Agreement may be amended only by a writing executed by both
Parties. 

  

	F.	Notices. 

  

	 	1.	All notices and other communications to Buyer or Seller shall be in writing and shall be electronically communicated, hand delivered or sent by overnight courier to either Party
hereto at the addresses as provided in this Section XV.F: 

 All communications intended for Buyer shall be sent to: 

PPM Energy Inc. 
 20333 State Highway 249

 Suite 310 
 Houston, Texas
77070 
 For Exercising Provisions Under this Contract Agreement: 
 Attention: Todd A. Blackford 
  

 27 

 Fax Number: 281-379-7444 
 email: todd.blackford@ppmenergy.com 
 For Monthly and Daily Scheduling Under this Contract Agreement:

 Attention: Zarin Imam or designee 
 Fax Number 281-379-7444 
 email: zarin.imam@ppmenergy.com 
 All communications intended for Seller shall be sent to: 
 Cheniere LNG Marketing, Inc. 
 717 Texas Avenue, Suite 3100 
 Houston, Texas 77002 
 Attention: Davis Thames

 Fax Number: 713-659-5459 
 email: dthames@cheniere.com 
 or at any other address of which either of the foregoing shall have notified the other in any manner
prescribed in this Section XV. 
  

	 	2.	For all purposes of this Agreement, a notice or communication will be deemed effective: 

  

	 	a.	if delivered by hand or sent by overnight courier, on the day it is delivered, or unless (i) that day is not a Business Day or (ii) if delivered after the close of
business on Business Day, then on the next succeeding Business Day; and 

  

	 	b.	if sent by facsimile transmission, on the date transmitted, provided that oral or written confirmation of receipt is obtained by the sender unless the date of transmission and
confirmation is not a Business Day, in which case on the next succeeding Business Day. 

  

	G.	The interpretation and performance of this Agreement shall be governed by the laws of New York, excluding, however, any conflict of laws rule which would apply the law of another
jurisdiction.  

  

	H.	The interpretation of this Agreement shall exclude any rights under legislative provisions conferring rights under a contract to Persons not a party to that contract. Nothing in
this Agreement shall otherwise be construed to create any duty to, or standard of care with reference to, or any obligations or liability to, any Person other than a Party. 

  

	I.	 Each Party to this Agreement represents and warrants that it has full and complete authority to enter into and perform this Agreement. Each Person who executes this

  

 28 

	 	 
Agreement on behalf of either Party represents and warrants that such Person has full and complete authority to do so and that such Party will be bound
thereby. 

  

	J.	The headings and subheadings contained in this Agreement are used solely for convenience and do not constitute a part of this Agreement between the Parties and shall not be used to
construe or interpret the provisions of this Agreement. 

  

	K.	Neither Party shall disclose directly or indirectly without the prior written consent of the other Party the terms of this Agreement to a third party (other than the employees,
lenders, counsel, accountants and other agents of the Party, or prospective purchasers of all or substantially all of a Party’s assets or of any rights under this Agreement, provided such Persons shall have agreed to keep such terms
confidential) except (i) in order to comply with any applicable law, order, regulation, or exchange rule, (ii) to the extent necessary for the enforcement of this Agreement, or (iii) to the extent such information is delivered to such
third party for the sole purpose of calculating a published index. Each Party shall notify the other Party of any proceeding of which it is aware which may result in disclosure of the terms of this Agreement (other than as permitted hereunder) and
use reasonable efforts to prevent or limit the disclosure. The existence of this Agreement is not subject to this confidentiality obligation. The terms of this Agreement shall be kept confidential by the Parties hereto for one (1) year from the
expiration of the Term. Each Party acknowledges that the other may be required, from time to time, to make disclosures and press releases and applicable filings with the Securities and Exchange Commission in accordance with applicable securities
laws that such Party believes in good faith are required by applicable law or the rules of any stock exchange. Each Party acknowledges that the other may be required from time to time to make filings in compliance with applicable securities laws,
including a copy of this Agreement. Each Party agrees that such disclosures shall not be a breach of this Agreement. 

  

	L.	In the event that disclosure is required by a governmental body or applicable law, the Party subject to such requirement may disclose the material terms of this Agreement to the
extent so required, but shall promptly notify the other Party, prior to disclosure, and shall cooperate (consistent with the disclosing Party’s legal obligations) with the other Party’s efforts to obtain protective orders or similar
restraints with respect to such disclosure at the expense of the other Party. 

  

	M.	This Agreement may be executed in any number of counterparts, each of which shall for all purposes be deemed to be an original; but such counterparts shall together constitute but
one and the same instrument. 

  

 29 

 IN WITNESS WHEREOF, each of the Parties has caused this Agreement to be duly executed and signed by its
duly authorized officer as of the Effective Date. 
  

			
	 Cheniere LNG Marketing, Inc., as Seller

		
	By:	 	 /s/ H. Davis Thames

	 Name:
	 	 H. Davis Thames

	 Title:
	 	 Vice President

	
	 PPM Energy, Inc., as Buyer

		
	By:	 	 /s/ Terry Hudgens

	 Name:
	 	 Terry Hudgens

	 Title:
	 	 President and CEO

  

 30 

 Exhibit A 
 Map of Cheniere Creole Trail Pipeline and Cheniere Sabine Pass Pipeline 
 

 
  

 31 

 Exhibit B 
 Form of Increase Notice 
 INCREASE NOTICE 
 [Date] 
 PPM Energy, Inc. 
 20333 State Hwy 249 
 Suite 310 
 Houston, Texas 77070 
 Attn: _________________________ 
 Sirs: 
 Pursuant to Section III.B.3 of that certain Gas Purchase Agreement dated as of
[            ] by and between Cheniere LNG Marketing, Inc. (“Cheniere”), as Seller, and PPM Energy, Inc, as Buyer, (as amended, supplemented or otherwise modified from time
to time, the “Agreement”), Cheniere hereby issues an Increase Notice under the Agreement, as follows: 
  

	 	a.	The incremental increase to the DCQ is: _______________________. 

  

	 	b.	Increase is effective 1st Day of:
______________________. 

  

	 	c.	Increase to be effective until final Day of: _______________________. 

 Pursuant to Section III.B.3.e of the Agreement, if Buyer elects to reject this Increase Notice, then Buyer must provide written notice to Cheniere within 30 days of the date of this Increase Notice. 
 Delivery of an executed counterpart of this Increase Notice by telecopier shall be effective as delivery of an original executed counterpart of this
Increase Notice. 
  

			
	 CHENIERE LNG MARKETING, INC.

		
	 By:
	 	  
	 Name:
	 	  
	 Title:
	 	  

  

 32 

 Exhibit C 
 BUYER GUARANTEE 
  

 33 

 Exhibit C 
 BUYER GUARANTEE 
 THIS GUARANTY, dated as of April 4, 2006, is issued by Scottish Power Finance
(US), Inc., a Delaware corporation, (“Guarantor”) in favor of Cheniere LNG Marketing, Inc., a Delaware corporation (“Guaranteed Party”). PPM Energy, Inc., an Oregon corporation, (“Obligor”) is a
wholly owned subsidiary of Guarantor. 
 RECITALS 
 A. Obligor and Guaranteed Party have entered into that certain Gas Purchase and Sale Agreement, dated as of April 4, 2006 (the “Agreement”). 
 B. This Guaranty is delivered to Guaranteed Party by Guarantor pursuant to the Agreement. 
 AGREEMENT 
 1. Guaranty. 
 A. Guaranty of Obligations Under the Agreement. For value received, Guarantor hereby absolutely, unconditionally and irrevocably,
subject to the express terms hereof, guarantees the payment when due of all payment obligations, whether now in existence or hereafter arising, by Obligor to Guaranteed Party pursuant to the Agreement (the “Obligations”). This
Guaranty is one of performance and not of collection and shall apply regardless of whether recovery of all such Obligations may be or become discharged or uncollectible in any bankruptcy, insolvency or other similar proceeding, or otherwise
unenforceable. 
 B. Maximum Guaranteed Amount. Notwithstanding anything to the contrary herein, Guarantor’s
aggregate obligation to Guaranteed Party hereunder in no event shall exceed the following amounts as designated (as applicable): 
  

	 	(i)	if the senior unsecured credit of Guarantor is rated “BBB+” or greater by S&P or “Baa1” or greater by Moody’s, provided that if Guarantor’s
senior unsecured credit is rated by both S & P and Moody’s, then the lower rating shall be applicable for purposes of this provision: One Hundred Million Dollars (U.S.$100,000,000); 

  

	 	(ii)	if the senior unsecured credit of Guarantor is rated no lower than “BBB-” by S&P and “Baa3” by Moody’s, provided that if Guarantor’s senior
unsecured credit is rated by both S & P and Moody’s, then the lower rating shall be applicable for purposes of this provision: Fifty Million Dollars (U.S.$50,000,000); or 

	 	(iii)	otherwise, zero (U.S. $0.00), 

 (the applicable amount being the
“Guarantee Limitation Amount”), including costs and expenses incurred by Guaranteed Party in enforcing this Guaranty, and shall not either individually or in the aggregate be greater or different in character or extent than the
obligations of Obligor to Guaranteed Party under the terms of the Agreement. IN NO EVENT SHALL GUARANTOR BE SUBJECT TO ANY CONSEQUENTIAL, EXEMPLARY, EQUITABLE, LOSS OF PROFITS, PUNITIVE, TORT OR OTHER SIMILAR DAMAGES. 
 2. Payment; Currency. All sums payable by Guarantor hereunder shall be made in freely transferable and immediately available funds and shall be
made in the currency in which the Obligations were due. If Obligor fails to pay any Obligation when due, the Guarantor will pay that Obligation directly to Guaranteed Party within five (5) days after written notice to Guarantor by Guaranteed
Party. The written notice shall provide a reasonable description of the amount of the Obligation and explanation of why such amount is due. 
 3. Waiver of Defenses. Except as set forth above, Guarantor hereby waives notice of acceptance of this Guaranty and of the Obligations and any action taken with regard thereto, and waives presentment, demand for payment, protest,
notice of dishonor or non-payment of the Obligations, suit, or the taking of and failing to take other action by Guaranteed Party against Obligor, Guarantor or others and waives any defense of a surety. Without limitation, Guaranteed Party may at
any time and from time to time without notice to or consent of Guarantor and without impairing or releasing the obligations of Guarantor hereunder: (a) make any change to the terms of the Obligations; (b) take or fail to take any action of
any kind in respect of any security for the Obligations; (c) exercise or refrain from exercising any rights against Obligor or others in respect of the Obligations or (d) compromise or subordinate the Obligations, including any security
therefor. Notwithstanding the foregoing, Guarantor shall be entitled to assert rights, setoffs, counterclaims and other defenses which Obligor may have to performance of any of the Obligations, other than defenses based upon lack of authority
of Obligor to enter into and/or perform its obligations under the Agreement or any insolvency, bankruptcy, reorganization, arrangement, composition, liquidation, dissolution or similar proceeding with respect to Obligor. 
 4. Term. This Guaranty shall continue in full force and effect until the end of the Term (as defined in the Agreement). Guarantor further agrees
that this Guaranty shall continue to be effective or be reinstated, as the case may be, if at any time payment, or any part thereof, of any Obligation is rescinded or must otherwise be restored or returned due to bankruptcy or insolvency laws or
otherwise. Guaranteed party shall return this original executed document to Guarantor within twenty (20) days of termination of this Guaranty. 
 5. Subrogation. Until all Obligations are indefeasibly performed in full, but subject to Section 6 hereof, Guarantor hereby waives all rights of subrogation, reimbursement, contribution and indemnity from Obligor with respect to
this Guaranty 

  

 2 

 
and any collateral held therefor, and Guarantor hereby subordinates all rights under any debts owing from Obligor to Guarantor, whether now existing or
hereafter arising, to the prior payment of the Obligations. 
 6. Expenses. Whether or not legal action is instituted, Guarantor
agrees to reimburse Guaranteed Party on written demand for all reasonable attorneys’ fees and all other reasonable costs and expenses incurred by Guaranteed Party in enforcing its rights under this Guaranty. Notwithstanding the foregoing, the
Guarantor shall have no obligation to pay any such costs or expenses if, in any action or proceeding brought by Guaranteed Party giving rise to a demand for payment of such costs or expenses, it is finally adjudicated that the Guarantor is not
liable to make payment under Section 2.1 hereof. 
 7. Assignment. Guarantor may not assign its rights or delegate its
obligations under this Guaranty in whole or part without written consent of Guaranteed Party (which consent shall not be unreasonably withheld, conditioned or delayed). Upon any such delegation and assumption of obligations, Guarantor shall be
relieved of and fully discharged from all obligations hereunder, whether such obligations arose before or after such delegation and assumption. 
 8. Non-Waiver. The failure of Guaranteed Party to enforce any provisions of this Guaranty at any time or for any period of time shall not be construed to be a waiver of any such provision or the right thereafter to enforce same. All
remedies of Guaranteed Party under this Guaranty shall be cumulative and shall be in addition to any other remedy now or hereafter existing at law or in equity. The terms and provisions hereof may not be waived, altered, modified or amended except
in a writing executed by Guarantor and Guaranteed Party. 
 9. Entire Agreement. Guarantor covenants that it will take actions under
the Guarantee and Support Agreement entered into between Guarantor and ScottishPower plc (“Parent”), dated as of December 12, 2005 (the “Support Agreement”) to make demand on Parent pursuant to the terms of the Support
Agreement and to provide Guaranteed Party with copies of notices which directly relate to the Guarantor received and made under the Support Agreement. Any payment obligation under this Guaranty is, if unpaid by Guarantor, an Obligation under the
Support Agreement and Guaranteed Party would be an “Obligee” under the Support Agreement. Guaranteed Party is specifically relying on the Support Agreement and the foregoing representation in accepting this Guaranty and entering into
transactions giving rise to the Obligations. Except as otherwise set forth in this Section 9, this Guaranty and the Agreement are the entire and only agreements between Guarantor and Guaranteed Party with respect to the guaranty of the
Obligations of Obligor by Guarantor. All agreements or undertakings heretofore or contemporaneously made, which are not set forth herein, are superseded hereby. 
 10. Notice. Any demand for payment, notice, request, instruction, correspondence or other document to be given hereunder by Guarantor or by Guaranteed Party shall be in writing and shall be deemed received
(a) if given personally, when received, (b) if mailed by certified mail (postage prepaid and return receipt requested), 

  

 3 

 
five days after deposit in the U.S. mails, (c) if given by facsimile, when transmitted with confirmed transmission or (d) if given via overnight
express courier service, when received or personally delivered, in each case with charges prepaid and addressed as follows (or such other address as either Guarantor or Guaranteed Party shall specify in a notice delivered to the other in accordance
with this Section): 
 If to Guarantor: 
 Scottish Power Finance (US), Inc. 
 1125 NW Couch, Suite 700 
 Portland, Oregon 97209 
 Attn: Treasurer/Credit Manager 
 If to Guaranteed Party: 
 Cheniere LNG Marketing, Inc. 
 c/o Cheniere Energy, Inc. 
 717 Texas Ave., Suite 3100 
 Houston, Texas 77002 
 Attn: Treasurer 
 11.
Counterparts. This Guaranty may be executed in counterparts, each of which when executed and delivered shall constitute one and the same instrument. 
 12. Governing Law; Jurisdiction. This Guaranty shall be governed by and construed in accordance with the laws of the state of New York without giving effect to principles of conflicts of law. Guarantor and
Guaranteed Party agree to the exclusive jurisdiction of any federal district court located in Harris County, Texas over any disputes arising or relating to this Guaranty. 
 13. Further Assurances. Guarantor shall cause to be promptly and duly taken, executed and acknowledged and delivered, such further documents and instruments as Guaranteed Party may from time to time reasonably
request in order to carry out the intent and purposes of this Guaranty. 
 14. Limitation on Liability. Except as specifically
provided in this Guaranty, Guaranteed Party shall have no claim, remedy or right to proceed against any past, present or future stockholder, partner, member, director or officer thereof for the payment of any of the Obligations, as the case may be,
or any claim arising out of any agreement, certificate, representation, covenant or warranty made by Obligor in the Agreement. 
 [SIGNATURE PAGE FOLLOWS] 
  

 4 

 IN WITNESS WHEREOF, the Guarantor has executed and delivered this Guaranty as of the date first set forth
above. 
  

			
	Scottish Power Finance (US), Inc., a Delaware corporation
		
	 By:
	 	  
	 Name:
	 	
	 Title:
	 	

  

			
	Acknowledged and agreed:
	
	Cheniere LNG Marketing, Inc.
		
	 By:
	 	  
	 Name:
	 	
	 Title
	 	

  

 5 

 Exhibit D 
 SELLER GUARANTEE 
  

 34 

 Exhibit D 
 SELLER GUARANTEE 
 THIS GUARANTY, dated as of April 4, 2006, is issued by Cheniere Energy, Inc.,
a Delaware corporation (“Guarantor”) in favor of PPM Energy, Inc., an Oregon corporation (“Guaranteed Party”). Cheniere LNG Marketing, Inc., a Delaware corporation, (“Obligor”) is a wholly owned
subsidiary of Guarantor. 
 RECITALS 
 A. Obligor and Guaranteed Party have entered into that certain Gas Purchase and Sale Agreement, dated as of April 4, 2006 (the “Agreement”). 
 B. This Guaranty is delivered to Guaranteed Party by Guarantor pursuant to the Agreement. 
 AGREEMENT 
 1. Guaranty. 
 A. Guaranty of Obligations Under the Agreement. For value received, Guarantor hereby absolutely, unconditionally and irrevocably,
subject to the express terms hereof, guarantees the payment when due of all payment obligations, whether now in existence or hereafter arising, by Obligor to Guaranteed Party pursuant to the Agreement (the “Obligations”). This
Guaranty is one of performance and not of collection and shall apply regardless of whether recovery of all such Obligations may be or become discharged or uncollectible in any bankruptcy, insolvency or other similar proceeding, or otherwise
unenforceable. 
 B. Maximum Guaranteed Amount. Notwithstanding anything to the contrary herein, Guarantor’s
aggregate obligation to Guaranteed Party hereunder in no event shall exceed the following amounts as designated (as applicable): 
  

	 	(i)	prior to the delivery of the first invoice under Article IX of the Agreement, Five Million Dollars (U.S. $5,000,000); or 

  

	 	(ii)	after delivery of the first invoice under Article IX of the Agreement, zero (U.S. $0.00), 

 including costs and expenses incurred by Guaranteed Party in enforcing this Guaranty, and shall not either individually or in the aggregate be greater or different in character or extent than the obligations of
Obligor to Guaranteed Party under the terms of the Agreement. IN NO EVENT SHALL GUARANTOR BE SUBJECT TO ANY CONSEQUENTIAL, EXEMPLARY, EQUITABLE, LOSS OF PROFITS, PUNITIVE, TORT OR OTHER SIMILAR DAMAGES. 

 2. Payment; Currency. All sums payable by Guarantor hereunder shall be made in freely transferable
and immediately available funds and shall be made in the currency in which the Obligations were due. If Obligor fails to pay any Obligation when due, the Guarantor will pay that Obligation directly to Guaranteed Party within five (5) days after
written notice to Guarantor by Guaranteed Party. The written notice shall provide a reasonable description of the amount of the Obligation and explanation of why such amount is due. 
 3. Waiver of Defenses. Except as set forth above, Guarantor hereby waives notice of acceptance of this Guaranty and of the Obligations and any
action taken with regard thereto, and waives presentment, demand for payment, protest, notice of dishonor or non-payment of the Obligations, suit, or the taking of and failing to take other action by Guaranteed Party against Obligor, Guarantor or
others and waives any defense of a surety. Without limitation, Guaranteed Party may at any time and from time to time without notice to or consent of Guarantor and without impairing or releasing the obligations of Guarantor hereunder: (a) make
any change to the terms of the Obligations; (b) take or fail to take any action of any kind in respect of any security for the Obligations; (c) exercise or refrain from exercising any rights against Obligor or others in respect of the
Obligations or (d) compromise or subordinate the Obligations, including any security therefor. Notwithstanding the foregoing, Guarantor shall be entitled to assert rights, setoffs, counterclaims and other defenses which Obligor may have to
performance of any of the Obligations, other than defenses based upon lack of authority of Obligor to enter into and/or perform its obligations under the Agreement or any insolvency, bankruptcy, reorganization, arrangement, composition, liquidation,
dissolution or similar proceeding with respect to Obligor. 
 4. Term. This Guaranty shall continue in full force and effect until the
end of the Term (as defined in the Agreement). Guarantor further agrees that this Guaranty shall continue to be effective or be reinstated, as the case may be, if at any time payment, or any part thereof, of any Obligation is rescinded or must
otherwise be restored or returned due to bankruptcy or insolvency laws or otherwise. Guaranteed party shall return this original executed document to Guarantor within twenty (20) days of termination of this Guaranty. 
 5. Subrogation. Until all Obligations are indefeasibly performed in full, but subject to Section 6 hereof, Guarantor hereby waives all rights
of subrogation, reimbursement, contribution and indemnity from Obligor with respect to this Guaranty and any collateral held therefor, and Guarantor hereby subordinates all rights under any debts owing from Obligor to Guarantor, whether now existing
or hereafter arising, to the prior payment of the Obligations. 
 6. Expenses. Whether or not legal action is instituted, Guarantor
agrees to reimburse Guaranteed Party on written demand for all reasonable attorneys’ fees and all other reasonable costs and expenses incurred by Guaranteed Party in enforcing its rights under this Guaranty. Notwithstanding the foregoing, the
Guarantor shall have no obligation to pay any such costs or expenses if, in any action or proceeding brought by 

 
Guaranteed Party giving rise to a demand for payment of such costs or expenses, it is finally adjudicated that the Guarantor is not liable to make payment
under Section 2.1 hereof. 
 7. Assignment. Guarantor may not assign its rights or delegate its obligations under this
Guaranty in whole or part without written consent of Guaranteed Party (which consent shall not be unreasonably withheld, conditioned or delayed). Upon any such delegation and assumption of obligations, Guarantor shall be relieved of and fully
discharged from all obligations hereunder, whether such obligations arose before or after such delegation and assumption. 
 8.
Non-Waiver. The failure of Guaranteed Party to enforce any provisions of this Guaranty at any time or for any period of time shall not be construed to be a waiver of any such provision or the right thereafter to enforce same. All remedies of
Guaranteed Party under this Guaranty shall be cumulative and shall be in addition to any other remedy now or hereafter existing at law or in equity. The terms and provisions hereof may not be waived, altered, modified or amended except in a writing
executed by Guarantor and Guaranteed Party. 
 9. Entire Agreement. This Guaranty and the Agreement are the entire and only agreements
between Guarantor and Guaranteed Party with respect to the guaranty of the Obligations of Obligor by Guarantor. All agreements or undertakings heretofore or contemporaneously made, which are not set forth herein, are superseded hereby. 

10. Notice. Any demand for payment, notice, request, instruction, correspondence or other document to be given hereunder by Guarantor or by
Guaranteed Party shall be in writing and shall be deemed received (a) if given personally, when received, (b) if mailed by certified mail (postage prepaid and return receipt requested), five days after deposit in the U.S. mails,
(c) if given by facsimile, when transmitted with confirmed transmission or (d) if given via overnight express courier service, when received or personally delivered, in each case with charges prepaid and addressed as follows (or such other
address as either Guarantor or Guaranteed Party shall specify in a notice delivered to the other in accordance with this Section): 
 If to Guarantor: 
 Cheniere Energy, Inc. 
 717 Texas Ave., Suite 3100 
 Houston, Texas 77002 
 Attn: Treasurer 
 If to Guaranteed Party: 
 PPM Energy, Inc. 
 1125 NW Couch, Suite 700 
 Portland, Oregon 97209 
 Attn: Legal 

 11. Counterparts. This Guaranty may be executed in counterparts, each of which when executed and
delivered shall constitute one and the same instrument. 
 12. Governing Law; Jurisdiction. This Guaranty shall be governed by and
construed in accordance with the laws of the state of New York without giving effect to principles of conflicts of law. Guarantor and Guaranteed Party agree to the exclusive jurisdiction of any federal district court located in Harris County, Texas
over any disputes arising or relating to this Guaranty. 
 13. Further Assurances. Guarantor shall cause to be promptly and duly
taken, executed and acknowledged and delivered, such further documents and instruments as Guaranteed Party may from time to time reasonably request in order to carry out the intent and purposes of this Guaranty. 
 14. Limitation on Liability. Except as specifically provided in this Guaranty, Guaranteed Party shall have no claim, remedy or right to proceed
against any past, present or future stockholder, partner, member, director or officer thereof for the payment of any of the Obligations, as the case may be, or any claim arising out of any agreement, certificate, representation, covenant or warranty
made by Obligor in the Agreement. 
 [SIGNATURE PAGE FOLLOWS] 

 IN WITNESS WHEREOF, the Guarantor has executed and delivered this Guaranty as of the date first set forth
above. 
  

			
	Cheniere Energy, Inc.
		
	 By:
	 	  
	 Name:
	 	
	 Title:
	 	

  

			
	Acknowledged and agreed:
	
	PPM Energy, Inc.
		
	 By:
	 	  
	 Name:
	 	
	 Title

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00103-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00103-of-00352.parquet"}]]