Document:

Exhibit 10

Exhibit 10.18

of Form 10-K
1997 EDITION

AIA DOCUMENT A111-1997

Standard Form of Agreement Between Owner and Contractor 

where the basis for payment is the COST OF THE WORK PLUS A FEE with a negotiated Guaranteed Maximum Price

A G R E E M E N T made as of the Twenty-Third day of October in the year Two Thousand 

(In words, indicate day, month and year )

	
This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification.

B E T W E E N the Owner:

(Name, address and other information)

Synthetech Inc .

1290 Industrial Way SW 

Albany, OR 97321

	
This document is not intended for use in competitive bidding.

 

and the Contractor:

(Name, address and other information)

R . L . Reimers Company 

3939 Old Salem Road Suite 200 

Albany, OR 97321

	
AlA Document A201

1997, General Conditions of the Contract for Construction, is adopted in this document by reference.

The Project is: (Name and address)

Synthetech Laboratory Remodel 

1290 Industrial Way SW

Albany, OR 97321

	
This document has been approved and endorsed by The Associated General Contractors of America.

 

The Architect is:

(Name, address and other information)

Industrial Design Corporation 

2020 SW 4th Avenue

Portland, OR 97201

The Owner and Contractor agree as follows.

Ó 1997 AIAâ The American Insitiute of Architects

AIA Document A111-1997 1735 New York Avenue, N.W.

OWNER-CONTRACTOR AGREEMENT Washington, D.C. 2006-5292

Copyright 1920, 1925, 1951, 1958, 1961, 1963, 1967, 1974, 1978, 1987, Ó 1997 by The American Institute of Architects. Reproduction of the material herein or substantial quotation of its provisions without written
permission of the AlA violates the copyright laws of the United States and will subject the violator to legal prosecution.

WARNING: unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

 

ARTICLE 1 THE CONTRACT DOCUMENTS

The Contract Documents consist of this Agreement, Conditions of the Contract (General, Supplementary and other Conditions), Drawings, Specifications, Addenda issued prior to execution of this Agreement, other documents listed in this Agreement and
Modifications issued after execution of this Agreement; these form the Contract, and are as fully a part of the Contract as if attached to this Agreement or repeated herein. The Contract represents the entire and integrated agreement between the parties
hereto and supersedes prior negotiations, representations or

agreements, either written or oral. An enumeration of the Contract Documents, other than Modifications, appears in Article 15. If anything in the other Contract Documents is inconsistent with this Agreement, this Agreement shall govern.

ARTICLE 2 THE WORK OF THIS CONTRACT

The Contractor shall fully execute the Work described in the Contract Documents, except to the extent specifically indicated in the Contract Documents to be the responsibility of others.

ARTICLE 3 RELATIONSHIP OF THE PARTIES

The Contractor accepts the relationship of trust and confidence established by this Agreement and covenants with the Owner to cooperate with the Architect and exercise the Contractor's skill and judgment in furthering the interests of the Owner; to
furnish efficient business administration and supervision; to furnish at all times an adequate supply of workers and materials; and to perform the Work in an expeditious and economical manner consistent with the Owner's interests. The Owner agrees to
furnish and approve, in a timely manner, information required by the Contractor and to make payments to the Contractor in accordance with the requirements of the Contract Documents.

ARTICLE 4 DATE OF COMMENCEMENT AND SU.STANTIAL COMPLETION

4.1 The date of commencement of the Work shall be the date of this Agreement unless a different date is stated below or provision is made for the date to be fixed in a notice to proceed issued by the Owner.

(Insert the date of commencement, if it differs from the date of this Agreement or, if applicable, state that the date will be fixed in a notice to proceed.) 

October 23, 2000.

If, prior to commencement of the Work, the Owner requires time to file mortgages, mechanic's liens and other security interests, the Owner's time requirement shall be as follows:

N/A

	The Contract Time shall be measured from the date of commencement. 

Ó 1997 AIAâ The American Insitiute of Architects

AIA Document A111-1997 1735 New York Avenue, N.W.

 OWNER-CONTRACTOR AGREEMENT Washington, D.C. 2006-5292

WARNING: unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

 

4.3 The Contractor shall achieve Substantial Completion of the entire Work not later than 180 days from the date of commencement, or as follows:

(Insert number of calendar days. Alternatively, a calendar date may

be used when coordinated with the date of commencement. Unless stated elsewhere in the Contract Documents, insert any requirements for earlier Substantial Completion of certain portions of the Work.)

,subject to adjustments of this Contract Time as provided in the Contract Documents.

(Insert provisions, if any, for liquidated damages relating to failure to complete on time, or for bonus payments for early completion of the Work.)

 

ARTICLE S BASIS FOR PAYMENT

5.1 CONTRACT SUM

5.1.1 The Owner shall pay the Contractor the Contract Sum in current funds for the Contractor's performance o[the Contract. The Contract Sum is the Cost of the Work as defined in Article 7 plus the Contractor's Fee.

5.1.2 The Contractor's Fee is:

(State a jump sum, percentage of Cost of the Work or other provision for determining the Contractors Fee, and describe the method of adjustment of the Contractors Fee for changes in the Work.)

See attached Rate Sheet, Exhibit "A"

5.2 GUARANTEED MAXIMUM PRICE

5.2.1 The sum of the Cost of the Work and the Contractor's Fee is guaranteed by the Contractor not to exceed Seven hundred ninety-one thousand one hundred twenty-five dollars($791,125), subject to additions and deductions by Change Order as provided
in the Contract Documents. Such maximum sum is referred to in the Contract Documents as the Guaranteed Maximum Price. Costs which would cause the Guaranteed Maximum Price to be exceeded shall be paid by the Contractor without reimbursement by the Owner. 

(Insert specific provisions if the Contractor is to participate in any savings.)

5.2.2 The Guaranteed Maximum Price is based on the following alternates, if any, which are described in the Contract Documents and are hereby accepted by the Owner:

(State the numbers or other identification of accepted alternates. If decisions on other alternates are to be made by the Owner subsequent to the execution of this Agreement, attach a schedule of such other alternates showing the amount for each and
the date when the amount expires.)

N/A
Ó 1997 AIAâ The American Insitiute of Architects

AIA Document A111-1997 1735 New York Avenue, N.W.

 OWNER-CONTRACTOR AGREEMENT Washington, D.C. 2006-5292

WARNING: unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

 

 

 

5.2.3 Unit prices, if any, are as follows:

N/A

5.2.4 Allowances, if any, are as follows: N/A

(Identify and state the amounts of any allowances, and state whether they include labor, materials, or both.)

5.2.5 Assumptions, if any, on which the Guaranteed Maximum Price is based are as follows:

HVAC system to be designed by Salem Heating & Sheet Metal, Inc. 

5.2.6 To the extent that the Drawings and Specifications are anticipated to require further development by the Architect, the Contractor has provided in the Guaranteed Maximum Price for such further development consistent with the Contract Documents
and reasonably inferable therefrom. Such further development does not include such things as changes in scope, systems, kinds and quality of materials, finishes or equipment, all of which, if required, shall be incorporated by Change Order.

ARTICLE 6 CHANGES IN THE WORK

6.1 Adjustments to the Guaranteed Maximum Price on account of changes in the Work may be determined by any of the methods listed in Subparagraph 7.3.3 of AlA Document A2O1-1997.

6.2 In calculating adjustments to subcontracts (except those awarded with the Owner's prior consent on the basis of cost plus a fee), the terms "cost" and "fee" as used in Clause 7.3.3.3 of AlA Document A2O1-1997 and the terms "costs" and "a
reasonable allowance for overhead and profit" as used in Subparagraph 7.3.6 of AlA Document A201-1997 shall have the meanings assigned to them in AlA Document A2O1-1997 and shall not be modified by Articles 5, 7 and 8 of this Agreement. Adjustments to
subcontracts awarded with the Owner's prior consent on the basis of cost plus a fee shall be calculated in accordance with the terms of those subcontracts.

6.3 In calculating adjustments to the Guaranteed Maximum Price, the terms "cost" and "costs" as used in the above-referenced provisions of AlA Document A201-1997 shall mean the Cost of the Work as defined in Article 7 of this Agreement and the terms
"fee" and "a reasonable allowance for overhead and profit" shall mean the Contractor's Fee as defined in Subparagraph 5.1.2 of this Agreement.

 
Ó 1997 AIAâ The American Insitiute of Architects

AIA Document A111-1997 1735 New York Avenue, N.W.

 OWNER-CONTRACTOR AGREEMENT Washington, D.C. 2006-5292

WARNING: unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

6.4 If no specific provision is made in Paragraph5.1 for

adjustment of the Contractor's Fee in the case of changes in the Work, or if the extent of such changes is such, in the aggregate, that application of the adjustment provisions of Paragraph 5.1 will cause substantial inequity to the Owner or
Contractor, the Contractor's Fee shall be equitably adjusted on the basis of the Fee established for the original Work, and the Guaranteed Maximum Price shall be ad justed accordingly.

ARTICLE 7 COSTS TO BE REIMBURSED

7.1 COST OF THE WORK

The term Cost of the Work shall mean costs necessarily incurred by the Contractor in the proper performance of the Work. Such costs shall be at rates not higher than the standard paid at the place of the Project except with prior consent of the Owner.
The Cost of the Work shall include only the items set forth in this Article 7.

7.2 LABOR COSTS

7.2.1 Wages of construction workers directly employed by the Contractor to perform the construction of the Work at the site or, with the Owner's approval, at off-site workshops.

7.2.2 Wages or salaries of the Contractor's supervisory and

administrative personnel when stationed at the site with the Owner's approval.

(If it is intended that the wages or salaries of certain personnel stationed at the Contractors principal or other offices shall be included in the Cost of the Work, identify in Article 14 the personnel to be included and whether for all or only part
of their time, and the rates at which their time will be charged to the Work.)

7.2.3 Wages and salaries of the Contractor's supervisory or administrative personnel engaged, at factories, workshops or on the road, in expediting the production or transportation of materials or equipment required for the Work, but only for that
portion of their time required for the Work.

7.2.4 Costs paid or incurred by the Contractor for taxes, insurance, contributions, assessments and benefits required by law or collective bargaining agreements and, for personnel not covered by such agreements, customary benefits such as sick leave,
medical and health benefits, holidays, vacations and pensions, provided such costs ~rebased on wages and salaries included in the Cost of the Work under Subparagraphs 7.2.1 through 7.2.3.

7.3 SUBCONTRACT COSTS

7.3.1 Payments made by the Contractor to Subcontractors in accordance with the requirements of the subcontracts.

7.4 COSTS OF MATERIALS AND EOUIPMENT INCORPORATED IN THE COMPLETED CONSTRUCTION

7.4.1 Costs, inquding transportation and storage, of materials and equipment incorporated or tobe incorporated in the completed construction.

7.4.2 Costs of materials described in the preceding Subparagraph 7.4.1 in excess of those actually installed to allowIor reasonable waste and spoilage. Unused excess materials, if any, shall become the Owner's property at the completion of the Work
or, at the Owner's option, shall be sold by the Contractor. Any amounts realized from such sales shall be credited to the Owner as a deduction from the Cost of the Work.

7.5 COSTS OF OTHER MATERIALS AND EOUIPMENT, TEMPORARY FACILITIES AND RELATED ITEMS

7.5.1 Costs, including transportation and storage, installation, maintenance, dismantling and removal of materials, supplies, temporary facilities, machinery, equipment, and hand tools not customarily owned by construction workers, that are provided
by the Contractor at the site and
Ó 1997 AIAâ The American Insitiute of Architects

AIA Document A111-1997 1735 New York Avenue, N.W.

 OWNER-CONTRACTOR AGREEMENT Washington, D.C. 2006-5292

WARNING: unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

 

fully consumed in the performance of the Work; and cost (less salvage value) of such items if not fully consumed, whether sold to others or retained by the Contractor. Cost for items previously used by the Contractor shall mean fair market value.

7.5.2 Rental charges for temporary facilities, machinery, equipment, and hand tools not customarily owned by construction workers that are provided by the Contractor at the site, whether rented from the Contractor or others, and costs of
transportation, installation, minor repairs and replacements, dismantling and removal thereof. Rates and quantities of equipment rented shall be subject to the Owner's prior approval.

7.5.3 Costs of removal of debris from the site.

7.5.4 Costs of document reproductions, facsimile transmissions and long-distance telephone calls, postage and parcel delivery charges, telephone service at the site and reasonable petty cash expenses of the site office.

7.5.5 That portion of the reasonable expenses of the Contractor's personnel incurred while traveling in discharge of duties connected with the Work.

7.5.6 Costs of materials and equipment suitably stored off the site at amutual1yacceptable location, if approved in advance by the Owner.

7.6 MISCELLANEOUS COSTS 

7.6.1 That portion of insurance and bond premiums that can be directly attributed to this Contract

7.6.2 Sales, use or similar taxes imposed by a governmental authority thar are related to the Work.

7.6.3 Fees and assessments for the building permit and for other permits, licenses and inspections for which the Contractor is required by the Contract Documents to pay.

7.6.4 Fees of laboratories for tests required by the Contract Documents, except those related to defective or nonconforming Work for which reimbursement is excluded by Subparagraph 13.5.3 of AIA Document A201-1997 or other provisions of the Contract
Documents, and which do not fall within the scope of Subparagraph 7.7.3.

7.6.5 Royalties and license fees paid for the use of a particular design, process or product required by the Contract Documents; the cost of defending suits or claims for infringement of patent rights arising from such requirement of the Contract
Documents; and payments made in accordance with legal judgments against the Contractor resulting from such suits or claims and payments of settlements made with the Owner's consent. However, such costs of legal defenses, judgments and settlements shall
not be included in the calculation of the Contractor's Fee or subject to the Guaranteed Maximum Price. If such royalties, fees and costs are excluded by the last sentence of Subparagraph 3.17.1 of AIA Document A201-1997 or other provisions of the Contract
Documents, then they shall not be included in the Cost of the Work.

7.6.6 Data processing costs related to the Work.

7.6.7 Deposits lost for causes other than the Contractor's negligence or specific responsibility to the Owner as set forth in the Contract Documents.
Ó 1997 AIAâ The American Insitiute of Architects

AIA Document A111-1997 1735 New York Avenue, N.W.

 OWNER-CONTRACTOR AGREEMENT Washington, D.C. 2006-5292

WARNING: unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

 

7.6.8 Legal, mediation and arbitration costs, including attorneys' fees, other than those arising from disputes between the Owner and Contractor, reasonably incurred by the Contractor in the performance of the Work and with the Owner's prior written
approval; which approval shall not be unreasonably withheld.

7.6.9 Expenses incurred in accordance with the Contractor's standard personnel policy for relocation and temporary living allowances of personnel required for the Work, if approved by the Owner.

7.7 OTHER COSTS AND EMERGENCIES

7.7.1 Other costs incurred in the performance of the Work if and to the extent approved in advance in writing by the Owner.

7.7.2 Costs due to emergencies incurred in taking action to prevent threatened damage, injury or loss incase of an emergency affecting the safety of persons and property, as provided in Paragraph 10.6of AIA Document A2O1-1997.

7.7.3 Costs of repairing or correcting damaged or nonconforming Work executed by the Contractor, Subcontractors or suppliers, provided that such damaged or nonconforming Work was not caused by negligence or failure to fulfill a specific responsibility
of the Contractor and only to the extent that the cost of repair or correction is not recoverable by the Contractor from insurance, sureties, Subcontractors or suppliers.

ARTICLE 8 COSTS NOT TO BE REIMBURSED 

8.1 The Cost of the Work shall not include:

8.1.1 Salaries and other compensation of the Contractor's personnel stationed at the Contractor's principal office or offices other than the site office, except as specifically provided in Subparagraphs 7.2.2 and 7.2.3 or as may be provided in Article
14.

8.1.2. Expenses of the Contractor's principal office and offices other than the site office.

8.1.3 Overhead and general expenses, except as may be expressly included in Article 7.

8.1.4 The Contractor's capital expenses, including interest on the Contractor's capital employed for the Work.

8.1.5 Rental costs of machinery and equipment, except as specifically provided in Subparagraph 7.5.2.

8.1.6 Except as provided in Subparagraph 7.7.3 of this Agreement, costs due to the negligence or failure to fulfill a specific responsibility of the Contractor, Subcontractors and suppliers or anyone directly or indirectly employed by any of them or
for whose acts any of them may be liable.

8.1.7 Any cost not specifically and expressly described in Article 7. 

8.1.8 Costs, other than costs included in Change Orders approved by the Owner, that would cause the Guaranteed Maximum Price to be exceeded.

ARTICLE 9 DISCOUNTS, REBATES AND REFUNDS

9.1 Cash discounts obtained on payments made by the Contractor shall accrue to the Owner if (1) before making the payment, the Contractor included them in an Application for Payment
Ó 1997 AIAâ The American Insitiute of Architects

AIA Document A111-1997 1735 New York Avenue, N.W.

 OWNER-CONTRACTOR AGREEMENT Washington, D.C. 2006-5292

WARNING: unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

 

and received payment therefor from the Owner, or (2) the Owner has deposited funds with the Contractor with which to make payments; otherwise, cash discounts shall accrue to the Contractor. Trade discounts, rebates, refunds and amounts received from
sales of surplus materials and equipment shall accrue to the Owner, and the Contractor shall make provisions so that they can be secured.

9.2 Amounts that accrue to the Owner in accordance with the provisions of Paragraph 9.1 shall be credited to the Owner as a deduction from the Cost of the Work.

ARTICLE 1O SUBCONTRACTS AND OTHER AGREEMENTS

1O.1 Those portions of the Work that the Contractor does not customarily perform with the Contractor's own personnel shall be performed under subcontracts or by other appropriate agreements with the Contractor. The Owner may designate specific persons
or entities from whom the Contractor shall obtain bids. The Contractor shall obtain bids from Subcontractors and from suppliers of materials or equipment fabricated especially for the Work and shall deliver such bids to the Architect. The Owner shall then
determine, with the advice of the Contractor and the Architect, which bids will be accepted. The Contractor shall not be required to contract with anyone to whom the Contractor has reasonable objection.

10.2 If a specific bidder among those whose bids are delivered by the Contractor to the Architect (1) is recommended to the Owner by the Contractor; (2) is qualified to perform that portion of the Work; and (3) has submitted a bid that conforms to the
requirements of the Contract Documents without reservations o( exceptions, but the Owner requires that another bid be accepted, then the Contractor may require that a Change Order be issued to ad just the Guaranteed Maximum Price by the difference between
the bid of the person or entity recommended to the Owner by the Contractor and the amount of the subcontract or other agreement actually signed with the person or entity designated by the Owner.

1O.3 Subcontracts or other agreements shall conform tothe

applicable payment provisions of this Agreement, and shall not be awarded on the basis of cost plus a fee without the prior consent of the Owner.

ARTICLE 11 ACCOUNTING RECORDS

The Contractor shall keep full and detailed accounts and exercise such controls as may be necessary for proper financial management under this Contract, and the accounting and control systems shall be satisfactory to the Owner. The Owner and the
Owner's accountants shall be afforded access to, and shall be permitted to audit and copy, the Contractor's records, books, correspondence, instructions, drawings, receipts, subcontracts, purchase orders, vouchers, memoranda and other data relating to
this Contract, and the Contractor shall preserve these for a period of three years after final payment, or for such longer period as may be required by law.

ARTICLE 12 PAYMENTS

12.1 PROGRESS PAYMENTS

12.1.1 Based upon Applications for Payment submitted to the Owner by the Contractor, the Owner shall make progress payments on account of the Contract Sum to the Contractor as provided below and elsewhere in the Contract Documents.

12.1.2 The period covered by each Application for Payment shall be one calendar month ending on the last day of the month, or as follows:

Terms are net 10 days.
Ó 1997 AIAâ The American Insitiute of Architects

AIA Document A111-1997 1735 New York Avenue, N.W.

 OWNER-CONTRACTOR AGREEMENT Washington, D.C. 2006-5292

WARNING: unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

 

12.1.3 Provided that an Application for Payment is received by the Owner not later than the 1st day of a month, the Owner shall make payment to the Contractor not later than the 1Oth day of the same month. If an Application for Payment is received by
the Owner after the application date fixed above, payment shall be made by the Owner not later than 10 days after the Owner receives the Application for Payment.

12.1.4 With each Application for Payment, the Contractor shall submit payrolls, petty cash accounts, receipted invoices or invoices with check vouchers attached, and any other evidence required by the Owner or Architect to demonstrate that cash
disbursements already made by the Contractor on account of the Cost of the Work equal or exceed (1) progress payments already received by the Contractor; less (2) that portion of those payments attributable to the Contractor's Fee; plus (3) payrolls for
the period covered by the present Application for Payment.

12.1.5 Each Application for Payment shall be based on the most recent schedule of values submitted by the Contractor in accordance with the Contract Documents. The schedule of values shall allocate the entire Guaranteed Maximum Price among the various
portions of the Work, except that the Contractor's Fee shall be shown as a single separate item. The schedule of values shall be prepared in such form and supported by such data to substantiate its accuracy as the Owner may require. This schedule, unless
objected to by the Owner, shall be used as a basis for reviewing the Contractor's Applications for Payment.

12.1.6 Applications for Payment shall show the percentage of completion of each portion of the Work as of the end of the period covered by the Application for Payment. The percentage of completion shall be the lesser of (1) the percentage of that
portion of the Work which has actually been completed; or (2) the percentage obtained by dividing (a) the expense that has actually been incurred by the Contractor on account of that portion of the Work for which the Contractor has made or intends to make
actual payment prior to the next Application for Payment by (b) the share of the Guaranteed Maximum Price allocated to that portion of the Work in the schedule of values.

12.1.7 Subject to other provisions of the Contract Documents, the amount of each progress payment shall be computed as follows:

 .1 take that portion of the Guaranteed Maximum Price properly allocable to completed Work as determined by multiplying the percentage of completion of each portion of the Work by the share of the Guaranteed Maximum Price allocated to that portion
of the Work in the schedule of values. Pending final determination of cost to the Owner of changes in the Work, amounts not in dispute shall be included as provided in Subparagraph 7.3.8 of AIA Document A201-1997;

 .2 add that portion of the Guaranteed Maximum Price properly allocable to materials and equipment delivered and suitably stored at the site for subsequent incorporation in the Work, or if approved in advance by the Owner, suitably stored off the
site at a location agreed upon in writing;

 .3 add the Contractor's Fee, less retainage of zero percent (0%). The Contractor's Fee shall be computed upon the Cost of the Work described in the two preceding Clauses at the rate stated in Subparagraph 5.1.2 or, if the Contractor's Fee is
stated as a fixed sum in that Subparagraph, shall be an amount that bears the same ratio to that fixed-sum fee as the Cost of the Work in the two preceding Clauses bears to a reasonable estimate of the probable Cost of the Work upon its completion;
.4 subtract the aggregate of previous payments made by the Owner; 

.5 subtract the shortfall, if any, indicated by the Contractor in the documentation required by Paragraph 12.14 to substantiate prior Applications for Payment, or resulting from errors subsequently discovered by the Owner's accountants in such
documentation; and

.6 subtract amounts, if any, for which the Architect has withheld or nullified a Certificate for Payment as provided in Paragraph 9.5

of AIA Document A2O1-1997. 
Ó 1997 AIAâ The American Insitiute of Architects

AIA Document A111-1997 1735 New York Avenue, N.W.

 OWNER-CONTRACTOR AGREEMENT Washington, D.C. 2006-5292

WARNING: unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

 

 

12.1.8 Except with the Owner's prior approval, paymentsto

Subcontractors shall be subject to retain age of not less than five percent (5%). The Owner and the Contractor shall agree upon a mutually acceptable procedure for review and approval of payments and retention for Subcontractors.

12.1.9 In taking action on the Contractor's Applications for Payment, the Architect shall be entitled to rely on the accuracy and completeness of the information furnished by the Contractor and shall not be deemed to represent that the Architect has
made a detailed examination, audit or arithmetic verification of the documentation submitted in accordance with Subparagraph 12.1.4 or other supporting data; that the Architect has made exhaustive or continuous on-site inspections or lhat the Architect
has made examinations to ascertain how or for what purposes the Contractor has used amounts previously paid on account of the Contract. Such examinations, audits and verifications, if required by the Owner, will be performed by the Owner's accountants
acting in the sole interest of the Owner.

12.2 FINAL PAYMENT

12.2.1 Final payment, constituting the entire unpaid balance of the Contract Sum, shall be made by the Owner to the Contractor when:

.1 the Contractor has fully performed the Contract except for the Contractor's responsibility to correct Work as providedin

Subparagraph 12.2.2 of AlA Document A201-1997, and to satisfy other requirements, if any, which extend beyond final payment; and

.2 a final Certificate for Payment has been issued by the Architect.

12.2.2 The Owner's final payment to the Contractor shall be made no later than 3O days after the issuance of the Architect's final Certificate for Payment, or as follows:

Terms are net 10 days.

12.2.3 The Owner's accountants will review and report in writing on the Contractor's final accounting within 3O days after delivery of the final accounting to the Architect by the Contractor. Based upon such Cost of the Work as the Owner's accountants
report to be substantiated by the Contractor's final accounting, and provided the other conditions of Subparagraph 12.2.1 have been met, the Architect win, within seven days after receipt of the written report of the Owner's accountants, either issue to
the Owner a final Certificate for Payment with a copy to the Contractor, or notify the Contractor and Owner in writing of the Architect's reasons for withholding a certificate as provided in Subparagraph 9.5.1 of the AIA Document A201-1997. The time
periods stated in this Subparagraph 12.2.3 supersede those stated in Subparagraph 9.4.1 of the AIA Document A201-1997.

12.2.4 If the Owner's accountants report the Cost of the Work as substantiated by the Contractor's final accounting to be less than claimed by the Contractor, the Contractor shall be entitled to demand arbitration of the disputed amount without a
further decision of the Architect. Such demand for arbitration shall be made by the Contractor within 30 days after the Contractor's receipt of a copy of the Architect's final Certificate for Payment; failure to demand arbitration within this 30~day
period shall result in the substantiated amount reported by the Owner's accountants becoming binding on the Contractor. Pending a final resolution by arbitration, the Owner shall pay the Contractor the amount certified in the Architect's final Certificate
for Payment.

12.2.5 If, subsequent to final payment and at the Owner's request, the Contractor incurs costs described in Article 7 and not excluded by Article 8 to correct defective or nonconforming Work,
Ó 1997 AIAâ The American Insitiute of Architects

AIA Document A111-1997 1735 New York Avenue, N.W.

 OWNER-CONTRACTOR AGREEMENT Washington, D.C. 2006-5292

WARNING: unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

 

 

the Owner shall reimburse the Contractor such costs and the Contractor's Fee applicable thereto on the same basis as if such costs had been incurred prior to final payment, but not in excess of the Guaranteed Maximum Price. If the Contractor has
participated in savings as provided in Paragraph 5.2, the amount of such savings shall be recalculated and appropriate credit given to the Owner in determining the net amount to be paid by the Owner to the Contractor.

ARTICLE 13 TERMINATION OR SUSPENSION

13.1 The Contract may be terminated by the Contractor, or by the Owner for convenience, as provided in Article 14of AIA Document A201-1997. However, the amount to be paid to the Contractor under Subparagraph 14.1.3 of AIA Document A2O1-1997 shall not
exceed the amount the Contractor would be entitled to receive under Paragraph 13.2 below, except that the Contractor's fee based on percentage of completion of the work.

13.2 The contract may be terminated by the Owner for cause as provided in Article 14 of AIA Document A20l-l997. The amount, if any, to be pa1d to the Contractor under Subparagraph 14.2.4 of AIA Document A201-1997 shall not cause the Guaranteed Maximum
Price to be exceeded, nor shall it exceed an amount calculated as follows:

13.2.1 Take the Cost of the Work incurred by the Contractor to the date of termination;

13.2.2 Add the Contractor's Fee computed upon the Cost of the Work to the date of termination at the rate stated in Subparagraph 5.1.2 or, if the Contractor's Fee is stated as a fixed sum in that Subparagraph, an amount that bears the same ratio to
that fixed-sum Fee as the Cost of the Work at the time of termination bears to a reasonable estimate of the probable Cost of the Work upon its completion; and

13.2.3 Subtract the aggregate of previous payments made by the Owner. 

13.3 The Qwner shall also pay the Contractor fair compensation, either by purchase or rental at the election of the Owner, for any equipment owned by the Contractor that the Owner elects to retain and that is not otherwise included in the Cost of the
Work under Subparagraph 13.2.1. To the extent that the Owner elects to take legal assignment of subcontracts and purchase orders (including rental agreements), the Contractor shall, as a condition of receiving the payments referred to in this Article 13,
execute and deliver all such papers and take all such steps, including the legal assignment of such subcontracts and other contractual rights of the Contractor, as the Owner may require for the purpose of fully vesting in the Owner the rights and benefits
of the Contractor under such subcontracts or purchase orders.

13.4 The Work may be suspended by the Owner as provided in Article 14 of AIA Document A201-1997; in such case, the Guaranteed Maximum Price and Contract T1me shall be increased as provided in Subparagraph 14.3.2 of AIA Document A20l-I997 except that
the term "profit" shall be understood to to mean the Contractor's Fee as described in Subparagraphs 5.1.2 and Paragraph 6.4 of this Agreement.

ARTICLE 14 MISCELLANEOUS PROVISIONS

14.1 Where reference is made in this Agreement to a provision AlA Document A201-1997 or another Contract Document, the reference refers to that provision as amended or supplemented by other provisions of the Contract Documents.
Ó 1997 AIAâ The American Insitiute of Architects

AIA Document A111-1997 1735 New York Avenue, N.W.

 OWNER-CONTRACTOR AGREEMENT Washington, D.C. 2006-5292

WARNING: unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

14.2 Payments due and unpaid under the Contract shall bear interest from the date payment is due at the rate stated below, or in the absence thereof, at the legal rate prevailing from time to time at the place where the Project is located.

(Insert rate of interest agreed upon, if any.)

18% APR {1.5%/month)

(Usury laws and requirements under the Federal Truth in Lending Act, similar state and local consumer credit laws and other regulations at the Owners and Contractor's principal places of business, the location of the Project and elsewhere may affect
the validity of this provision. Legal advice should be obtained with respect to deletions or modifications, and also regarding requirements such as written disclosures or waivers.)

14.3 The Owner's representative is: 

(Name, address and other information.)

Dennis Willhite

Synthetech Inc .

1290 Industrial Way SW

Albany ,OR 97321

14.4 The Contractor's representative is:

(Name, address and other information.)

Ronald Reimers

R.L. Reimers Company

3939 Old Salem Road Suite 200

Albany, OR 97321

14.5 Neither the Owner's nor the Contractor's representative shall be changed without ten days written notice to the other party.

14.6

Other provisions:

ARTICLE 15 ENUMERATION OF CONTRACT DOCUMENTS

15.1 The Contract Documents, except for Modifications issued after execution of this Agreement, are enumerated as follows:

15.1.1 The Agreement is this executed 1997 edition of the Standard Form of Agreement Between Owner and Contractor, AIA Document A111-1997.

15.1.2 The General Conditions are the 1997 edition of the General Conditions of the Contract for Construction, AlA Document A2O1-1997.

 
Ó 1997 AIAâ The American Insitiute of Architects

AIA Document A111-1997 1735 New York Avenue, N.W.

 OWNER-CONTRACTOR AGREEMENT Washington, D.C. 2006-5292

WARNING: unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

 

15.1.3 The Supplementary and other Conditions of the Contract are those contained in the Project Manual dated August 11 , 2000 , and are as follows:

Document Title Pages

Specifications for the Construction of Laboratory Remodel, Rev. 0 

15.1.4 The Specifications are those contained in the Project Manual dated as in Subparagraph 15.1.3, and are as follows:

(Either list the Specifications here or refer to an exhibit attached to this Agreement.)

Section Title Pages

See attached exhibit "B"

15.1.5 The Drawings are as follows, and are dated August 16, 2000 unless different date is shown below:

(Either list the Drawings here or refer to an exhibit attached to this Agreement.)

Number Title Date

See attached exhibit "C"

 
Ó 1997 AIAâ The American Insitiute of Architects

AIA Document A111-1997 1735 New York Avenue, N.W.

 OWNER-CONTRACTOR AGREEMENT Washington, D.C. 2006-5292

WARNING: unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

 

15.1.6

The Addenda, if any, are as follows:

Number Date Pages

N/A

Portions of Addenda relating to bidding requirements are not part of the Contract Documents unless the bidding requirements are also enumerated in this Article 15.

15.1.7 Other Documents, if any, forming part of the Contract Documents are as follows:

{List here any additional documents, such as a list of alternates that are intended to form part of the Contract Documents. AIA Document A2O1-1997 provides that bidding requirements such as advertisement or invitation to bid, Instructions to Bidders,
sample forms and the Contractors bid are not part of the Contract Documents unless enumerated in this Agreement. They should be listed here only if intended to be part of the Contract Documents.)

Original budget dated September 8, 2000.

Revised budget dated October 17, 2000.

Letter dated October 17, 2000, listing deletions from original bid. 

Field change Order No.02 dated November 28, 2000.

 
Ó 1997 AIAâ The American Insitiute of Architects

AIA Document A111-1997 1735 New York Avenue, N.W.

 OWNER-CONTRACTOR AGREEMENT Washington, D.C. 2006-5292

WARNING: unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

ARTICLE 16 INSURANCE AND BONDS

(List required limits of liability for insurance and bonds. AIA Document A201-1997 gives other specific requirements for insurance and bonds.)

See attached Certificate of Insurance.

 

 

This agreement is entered into as of the day and year first written above and is executed in at least three original copies, of which one is to be delivered to the Contractor, one to the Architect for use in the administration of the Contract, and the
remainder to the Owner.

Synthetech, Inc.

	
By:/s/ Chares B. Williams
	
/s/ Ronald R. Reimers

	
OWNER (Signature)
	
CONTRACTOR (Signature)

	
Charles B. Williams, VP & CFO
	
Ronald R. Reimers, President

 

CAUTION: You should sign an original AIA document or a licensed reproduction. Originals contain the AIA logo printed in red; licensed reproductions are those produced in accordance wit the Instructions to this document.

 
Ó 1997 AIAâ The American Institute of Architects

AIA Document A111-1997 1735 New York Avenue, N.W.

 OWNER-CONTRACTOR AGREEMENT Washington, D.C. 2006-5292

WARNING: unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution.

 

	
<Table>
	
	
	
	
	
	
	

	
<Caption>
	
	
	
	
	
	
	

	
<S><C>
	
<C>
	
<C>
	
<C>
	
<C>
	
<C>
	
<C>
	
<C>

	
Schedule of Purchase Orders ("PO")
	
	
	
	
	

	
Vendor:

R. L. Reimers Co.
	
	
	
	
	

	
3514 Conser Rd., NE
	
	
	
	
	

	
Albany, OR  97321
	
	
	
	
	

	
	
	
	
	
	
	
	

	
	
	
	
	
	
	
	

	
PO Number
	
PO Date
	
Requisitioner
	
Terms
	
Qty
	
Description
	
Unit Price
	
Total

	
	
	
	
	
	
	
	

	
16329
	
8-Nov-2000
	
J.Melka
	
Net 10 Days
	
1
	
R&D Lab Remodel per pending lawyer review
	
852,212.00 
	
852,212.00 

	
16337
	
13-Nov-2000
	
D. Willhite
	
Net 10 Days
	
1
	
Asbestos removal from R&D Lab area
	
3,444.00 
	
3,444.00 

	
16353
	
15-Dec-2000
	
D. Willhite
	
Net 10 Days
	
9
	
Kussel floor drains for R&D Lab project.  Floor drains are of sanitary
	
550.00 
	
4,950.00 

	
	
	
	
	
	
design.
	
	

	
16373
	
7-Feb-2001
	
D.Willhite
	
Net 10 Days
	
1
	
R&D Lab change order - add electrical accomodations to move 
	
3,162.50 
	
3,162.50 

	
	
	
	
	
	
Rotovaps back into R&D lab area.
	
	

	
16374
	
7-Feb-2001
	
D.Willhite
	
Net 10 Days
	
1
	
R&D Lab change order - cost increase for better floor coating from
	
12,620.30 
	
12,620.30 

</Table>Exhibit 10

Exhibit 10.16

of Form 10-K

PROMISSORY NOTE

	
Principal
	
Loan Date
	
 Maturity
	
 Loan No.
	
Call
	
Collateral
	
Account
	
Officer
	
Initials

	
$1,000,000
	
10-12-2000
	
08-31-2001
	
430-18/26
	 	
010
	 	
M M73
	 

References in the shaded area are for Lender's use only and do not limit the applicability of this document to any particular loan or item

	
Borrower:
	
Synthetech, Inc.
	
Lender: U.S. Bank National Association
	 	 
	 	
1290 Industrial Way Albany, OR 97321
	
Greater Willamette Business Banking Center
	 	 
	 	 	
PL-7 Commercial Loan Service West
	 	 
	 	 	
555 S. W. Oak Street
	 	 
	 	 	
Portland, OR 97204
	 	 
	 	 	 
	
Principal Amount: $1,000,000.00
	
 Initial Rate: 9.500%
	
Date of Note: October 12, 2000

 

PROMISE TO PAY. Synthetech, Inc. ("Borrower") promises to pay to U. S. BANK NATIONAL ASSOCIATION ("Lender"), or order, In lawful money of the united States of America, the principal amount of One Million & 00/100 Dollars
($1,000,000.00) or so much as may be outstanding, together with Interest on the unpaid outstanding principal balance of each advance. Interest shall be calculated from the date of each advance until repayment of each advance.

PAYMENT. Borrower will pay this loan on demand, or if no demand is made, in one payment of all outstanding principal plus all accrued unpaid interest on August 31, 2001. In addition, Borrower will pay regular monthly payments of
accrued unpaid interest beginning November 30, 2000, and all subsequent interest payments are due on the last day of each month after that. The annual interest rate for this Note is computed on a 365/360 basis; that is, by applying the ratio of the annual interest rate over a year of 360 days, multiplied by the outstanding principal balance, multiplied by the actual number of days the
principal balance is outstanding. Borrower will pay Lender at lender's address shown above or at such other place as Lender may designate in writing.

VARIABLE INTEREST RATE. The interest rate on this Note is subject to change from time to time based on changes in an index which is the Lender's Prime Rate. This is the rate of interest which Lender from time to time establishes
as its Prime Rate and is not, for example, the lowest rate of interest which Lender collects from any borrower or class of borrowers (the "Index"). The interest rate shall be adjusted without notice effective on the day Lender's prime rate changes. Lender
will tell Borrower the current Index rate upon Borrower's request. Borrower understands that Lender may make loans based on other rates as well. The interest rate change will not occur more often than each Day. The Index currently is 9.500% per annum. The Interest rate to be applied to the unpaid principal balance of this Note will be at a rate equal to the Index, resulting in an Initial rate of 9.500% per annum.

PREPAYMENT. Borrower agrees that all loan fees and other prepaid finance charges are earned fully as of the date of the loan and will not be subject to refund upon early payment (whether voluntary or as a result of default), except
as otherwise required by law.

 

Except for the foregoing, Borrower may pay without penalty all or a portion of the amount owed earlier than it is due. Early payments will not, unless agreed to by Lender in writing, relieve Borrower of Borrower's obligation to
continue to make payments of accrued unpaid interest. Rather, they will reduce the principal balance due.

 

DEFAULT. Borrower will be in default if any of the following happens: (a) Borrower fails to make any payment when due. (b) Borrower breaks any promise Borrower has made to Lender, or Borrower fails to comply with or to
perform when due any other term, obligation, covenant, or condition contained in this Note or any agreement related to this Note, or in any other agreement or loan Borrower has with Lender. (c) Borrower defaults under any loan, extension of credit,
security agreement, purchase or sales agreement, or any other agreement, in favor of any other creditor or person that may materially affect any of Borrower's property or Borrower's ability to repay this Note or perform Borrower's obligations under this
Note or any of the Related Documents. (d) Any representation or statement made or furnished to Lender by Borrower or on Borrower's behalf is false or misleading in any material respect either now or at the time made or furnished. (e) Borrower becomes
insolvent, a receiver is appointed for any part of Borrower's property, Borrower makes an assignment for the benefit of creditors, or any proceeding is commenced either by Borrower or against Borrower under any bankruptcy or insolvency laws. (f) Borrower
is in default under any other note, security agreement, lease agreement or lease schedule, loan agreement or other agreement, whether now existing or hereafter made, between Borrower and U.S. Bancorp or any direct or indirect subsidiary of U.S. Bancorp
(g) Any creditor tries to take any of Borrower's property on or in which Lender has a lien or security interest. This includes a garnishment of any of Borrower's accounts with Lender. (h) Any guarantor dies or any of the other events described in this
default section occurs with respect to any guarantor of this Note. (i) A material adverse change occurs in Borrower's financial condition, or Lender believes the prospect of payment or performance of the Indebtedness is impaired. (j) Lender in good faith
deems itself insecure.

LENDER'S RIGHTS. Upon default, Lender may declare the entire unpaid principal balance on this Note and all accrued unpaid interest immediately due, without notice, and then Borrower will pay that amount. Upon default, including
failure to pay upon final maturity, Lender, at its option, may also, if permitted under applicable law, increase the variable interest rate on this Note to 5.000 percentage points over the Index. The interest rate will not exceed the maximum rate
permitted by applicable law. Lender may hire or pay someone else to help collect this Note if Borrower does not pay. Borrower also will pay Lender that amount. This includes, subject to any limits under applicable law, Lender's attorneys' fees and
Lender's legal expenses whether or not there is a lawsuit, including attorneys' fees and legal expenses for bankruptcy proceedings (including efforts to modify or vacate any automatic stay or injunction), appeals, and any anticipated post-judgment
collection services. If not prohibited by applicable law, Borrower also will pay any court costs, in addition to all other sums provided by law. This Note has been delivered to Lender and accepted by Lender in the State of Oregon. If there is a lawsuit, Borrower agrees upon Lender's request to submit to the jurisdiction of the courts of Multnomah County, the State of Oregon. Subject to the
provisions on arbitration, this Note shall be governed by and construed in accordance with the laws of the State of Oregon.

RIGHT OF SETOFF. Borrower grants to Lender a contractual security interest in, and hereby assigns, conveys, delivers, pledges, and transfers to Lender all Borrower's right, title and interest in and to, Borrower's accounts with
Lender (whether checking, savings, or some other account), including without limitation all accounts held jointly with someone else and all accounts Borrower may open in the future, excluding however all IRA and Keogh accounts, and all trust accounts for
which the grant of a security interest would be prohibited by law. Borrower authorizes Lender, to the extent permitted by applicable law, to charge or setoff all sums owing on this Note against any and all such accounts.

LINE OF CREDIT. This Note evidences a revolving line of credit. Advances under this Note may be requested orally by Borrower or by an authorized person. Lender may, but need not, require that all oral requests be confirmed in
writing. All communications, instructions, or directions by telephone or otherwise to Lender are to be directed to Lender's office shown above. Borrower agrees to be liable for all sums either: (a) advanced in accordance with the instructions of an
authorized person or (b) credited to any of Borrower's accounts with Lender, regardless of the fact that persons other than those authorized to borrow have authority to draw against the accounts. The unpaid principal balance owing on this Note at any time
may be evidenced by endorsements on this Note or by Lender's internal records, including daily computer print-outs. Lender will have no obligation to advance funds under this Note if: (a) Borrower or any guarantor is in default under the terms of this
Note or any agreement that Borrower or any guarantor has with Lender, including any agreement made in connection with the signing of this Note; (b) Borrower or any guarantor ceases doing business or is insolvent; (c) any guarantor seeks, claims or
otherwise attempts to limit, modify or revoke such guarantor's guarantee of this Note or any other loan with Lender; (d) Borrower has applied funds provided pursuant to this Note for purposes other than those authorized by Lender; or (e) Lender in good
faith deems itself insecure under this Note or any other agreement between Lender and Borrower.

ARBITRATION. Lender and Borrower agree that all disputes, claims and controversies between them, whether individual, joint, or class in nature, arising from this Note or otherwise, including without limitation contract and tort
disputes, shall be arbitrated pursuant to the Rules of the American Arbitration Association, upon request of either party. No act to take or dispose of any collateral securing this Note shall constitute a waiver of this arbitration agreement or be prohibited by this arbitration agreement. This includes, without limitation, obtaining injunctive relief or a temporary
restraining order; foreclosing by notice and sale under any deed of trust or mortgage; obtaining a writ of attachment or imposition of a receiver; or exercising any rights relating to personal property, including taking or disposing of such property with
or without judicial process pursuant to Article 9 of the Uniform Commercial Code. Any disputes, claims, or controversies concerning the lawfulness or reasonableness of any act, or exercise of any right, concerning any collateral securing this Note,
including any claim to rescind, reform, or otherwise modify any agreement relating to the collateral securing this Note, shall also be arbitrated, provided however that no arbitrator shall have the right or the power to enjoin or restrain any act of any
party. Judgment upon any award rendered by any arbitrator may be entered in any court having jurisdiction. Nothing in this Note shall preclude any party from seeking equitable relief from a court of competent jurisdiction. The statute of limitations,
estoppel, waiver, laches, and similar doctrines which would otherwise be applicable in an action brought by a party shall be applicable in any arbitration proceeding, and the commencement of an arbitration proceeding shall be deemed the commencement of an
action for these purposes. The Federal Arbitration Act shall apply to the construction, interpretation, and enforcement of this arbitration provision.

 

LATE CHARGE. If a payment is 19 days or more past due, Borrower will be charged a late charge of 5% of the delinquent payment.

RENEWAL AND EXTENSION. This Note is given in renewal and extension and not in novation of the following described indebtedness: That certain Promissory Note dated August 26, 1998 in the amount of $1,000,000.00 executed by
Borrower payable to Lender.

10-12-2000PROM1SSORY NOTEPage 2
(Continued)

LATE CHARGE. If a payment is 19 days or more past due, Borrower will be charged a late charge of 5% of the delinquent payment.

RENEWAL AND EXTENSION. This Note is given in renewal and extension and not in novation of the following described indebtedness: That certain Promissory Note dated August 26, 1998 in the amount of $1,000,000.00 executed by Borrower
payable to Lender.

 

GENERAL PROVISION. This Note is payable on demand. The inclusion of specific default provisions or rights of lender shall not preclude Lender's right to declare payment of this Note on its demand. Lender may delay or
forgo enforcing any of its rights or remedies under this Note without losing them. Borrower and any other person who signs, guarantees or endorses this Note, to the extent allowed by law, waive presentment, demand for payment, protest and notice of
dishonor. Upon any change in the terms of this Note, and unless otherwise expressly stated in writing, no party who signs this Note, whether as maker, guarantor, accommodation maker or endorser, shall be released from liability. All such parties agree
that Lender may renew or extend (repeatedly and for any length of time) this loan, or release any party or guarantor or collateral; or impair, fail to realize upon or perfect Lender's security interest in the collateral; and take any other action deemed
necessary by Lender without the consent of or notice to anyone. All such parties also agree that Lender may modify this loan without the consent of or notice to anyone other than the party with whom the modification is made.

UNDER OREGON LAW MOST AGREEMENTS, PROMISES AND COMMITMENTS MADE BY US (LENDER) AFTER OCTOBER 3, 1989 CONCERNING LOANS AND OTHER CREDIT EXTENSIONS WHICH ARE NOT FOR PERSONAL FAMIL Y OR HOUSEHOLD PURPOSES OR SECURED
SOLELY BY THE BORROWER'S RESIDENCE MUST BE IN WRITING, EXPRESS CONSIDERATION AND BE SIGNED BY US TO BE ENFORCEABLE.

PRIOR TO SIGNING THIS NOTE, BORROWER READ AND UNDERSTOOD ALL THE PROVISIONS OF THIS NOTE, INCLUDING THE VARIABLE INTEREST RATE PROVISIONS. BORROWER AGREES TO THE TERMS OF THE NOTE AND ACKNOWLEDGES RECEIPT OF A COMPLETED COPY OF THE NOTE.

BORROWER:

Synthetech, Inc.

	
X /s/ M. Sreenivasan, President & CEO
	
X /s/ Charles B. Williams, Vice President & CFO

	
Authorized Signer, Title as of 10/12/00
	
Authorized Signer, Title as of 10/12/00

LENDER:

U. S. BANK NATIONAL ASSOCIATION

BY:/s/ Mike McNulty, V.P.

Authorized Officer

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00026-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00026-of-00352.parquet"}]]