Document:

EX-10.5

 EXHIBIT 10.5 

FORM OF 
 INDEMNIFICATION
AGREEMENT 
 THIS INDEMNIFICATION AGREEMENT (“Agreement”) is made and entered into as of
                    , 2015 by and between DC Industrial Liquidating Trust, a Maryland statutory trust (the “Trust”), and
                    , a trustee and/or officer of the Trust (the “Indemnitee”). 

RECITALS 
 WHEREAS, the
Trust was formed for the purpose of liquidating certain assets of Industrial Income Trust Inc. (“IIT”) in connection with the merger of IIT with and into Western Logistics II LLC as contemplated by that certain Agreement and Plan of
Merger, dated as of July 28, 2015, by and among IIT, Western Logistics LLC and Western Logistics II LLC; and 
 WHEREAS, the
interpretation of the provisions of statutes, regulations and governing instruments regarding indemnification of trustees and officers may be too uncertain to provide such trustees and officers with adequate notice of the legal, financial and other
risks to which they may be exposed by virtue of their service as such; and 
 WHEREAS, damages sought against trustees and officers
in litigation may be substantial, and the costs of defending such actions and of judgments in favor of plaintiffs or of settlement therewith may be prohibitive for individual trustees and officers, without regard to the merits of a particular action
and without regard to the culpability of, or the receipt of improper personal benefit by, any named trustee or officer; and 

WHEREAS, the long period of time which may elapse before final disposition of such litigation may impose undue hardship and burden on a
trustee or officer or his estate in maintaining a proper and adequate defense of himself or his estate against claims for damages; and 

WHEREAS, the Trust is organized under the Maryland Statutory Trust Act (the “Statutory Trust Act”), and
Section 12-403 of the Statutory Trust Act empowers statutory trusts to indemnify and advance expenses of litigation to a person serving as a trustee, officer, employee or agent of a statutory trust; and 

WHEREAS, the Amended and Restated Agreement and Declaration of Trust of the Trust (the “Trust Agreement”) provides
that the Trust shall indemnify the Trustees, and each person appointed by the Trustees pursuant to the terms thereof, including the Advisor, and directors, officers, employees, managers and agents of each Trustee; and 

WHEREAS, the Board of Trustees of the Trust (the “Board of Trustees”) has concluded that it is in the best interests
of the Trust to enter into an agreement to indemnify in a reasonable and adequate manner the Indemnitee and to assume for itself maximum liability for expenses and damages in connection with claims lodged against him for his decisions and actions as
a trustee and/or officer of the Trust; and 

 NOW, THEREFORE, in consideration of the foregoing, and of other good and valuable
consideration, the receipt and sufficiency of which is acknowledged by each of the parties hereto, the parties agree as follows: 

ARTICLE I 
 DEFINITIONS

 For purposes of this Agreement, the following terms shall have the meanings set forth below: 

Section 1.1 “Applicable Legal Rate” shall mean a fixed rate of interest equal to the applicable federal rate for mid-term
debt instruments as of the day that it is determined that the Indemnitee must repay any advanced expenses. 
 Section 1.2
“Beneficiaries” shall mean the holders of units of beneficial interests in the Trust. 
 Section 1.3
“Corporate Status” shall mean the status of a person who is or was a trustee, officer, employee or agent of the Trust, or a member of any committee of the Trust, and the status of a person who, while a trustee, officer, employee or
agent of the Trust, is or was serving at the request of the Trust as a director, trustee, officer, partner (including service as a general partner of any limited partnership), manager, managing member, fiduciary, employee or agent of another foreign
or domestic corporation, real estate investment trust, partnership, limited liability company, joint venture, trust, other incorporated or unincorporated entity or enterprise or employee benefit plan. As a clarification and without limiting the
circumstances in which the Indemnitee may be serving at the request of the Trust, service by the Indemnitee shall be deemed to be at the request of the Trust if the Indemnitee serves or served as a director, trustee, officer, partner, manager,
managing member, fiduciary, employee or agent of any corporation, real estate investment trust, partnership, limited liability company, joint venture, trust, other incorporated or unincorporated entity or enterprise or employee benefit plan
(a) of which a majority of the voting power or equity interest is owned directly or indirectly by the Trust or (b) the management of which is controlled directly or indirectly by the Trust. 

Section 1.4 “Disinterested Trustee” shall mean a trustee of the Trust who neither is nor was a party to the Proceeding
in respect of which indemnification and/or advance of Expenses is being sought by the Indemnitee. 
 Section 1.5 “Effective
Date” shall mean the date set forth in the first paragraph of this Agreement. 
 Section 1.6 “Expenses” shall
mean without limitation expenses of Proceedings including all attorneys’ fees, retainers, court costs, transcript costs, fees of experts, investigation fees and expenses, accounting and witness fees, travel expenses, duplicating costs, printing
and binding costs, telephone charges, postage, delivery service fees, federal, state, local or foreign taxes imposed on the Indemnitee as a result of the actual or deemed receipt of any payments under this Agreement and all other disbursements or
expenses of the types customarily incurred in connection with prosecuting, defending, preparing to prosecute or defend, investigating or being or preparing to be a witness in or otherwise participating in a Proceeding. “Expenses” shall
also include Expenses incurred in connection with any appeal resulting from any Proceeding including, without limitation, the premium for, security for and other costs relating to any cost bond, supersedeas bond or other appeal bond or its
equivalent. 

  
 2 

 Section 1.7 “Independent Counsel” shall mean a law firm, or a member of a
law firm, that is experienced in matters of law of business entities and neither is, nor in the past five years has been, retained to represent: (a) the Trust or the Indemnitee in any matter material to either such party (other than with
respect to matters concerning the Indemnitee under this Agreement or of other indemnitees under similar indemnification agreements), or (b) any other party to or participant or witness in the Proceeding giving rise to a claim for
indemnification or advance of Expenses hereunder. Notwithstanding the foregoing, the term “Independent Counsel” shall not include any person who, under the applicable standards of professional conduct then prevailing, would have a conflict
of interest in representing either the Trust or the Indemnitee in an action to determine the Indemnitee’s rights under this Agreement. 

Section 1.8 “Liabilities” shall mean liabilities of any type whatsoever, including, without limitation, any judgments,
fines, excise taxes and penalties under the Employee Retirement Income Security Act of 1974, as amended, penalties and amounts paid in settlement (including all interest, assessments and other charges paid or payable in connection with or in respect
of such judgments, fines, penalties or amounts paid in settlement) in connection with the investigation, defense, settlement or appeal of any Proceeding or any claim, issue or matter therein. 

Section 1.9 “Proceeding” shall mean any threatened, pending or completed action, suit, arbitration, alternate dispute
resolution mechanism, investigation, inquiry, administrative hearing or any other actual, threatened or completed proceeding, whether brought by or in the right of the Trust or otherwise and whether of a civil (including intentional or unintentional
tort claims), criminal, administrative or investigative (formal or informal) nature, including any appeal therefrom, except one pending or completed on or before the Effective Date, unless otherwise specifically agreed in writing by the Trust and
the Indemnitee. If the Indemnitee reasonably believes that a given situation may lead to or culminate in the institution of a Proceeding, such situation shall also be considered a Proceeding. 

ARTICLE II 
 TERMINATION
OF AGREEMENT 
 This Agreement shall continue until the termination of the Trust. 

ARTICLE III 
 SERVICE BY
INDEMNITEE, NOTICE OF PROCEEDINGS 
 AND DEFENSE OF CLAIMS 

Section 3.1 Notice of Proceedings. The Indemnitee shall notify the Trust promptly in writing upon being served with any summons,
citation, subpoena, complaint, indictment, information or other document relating to any Proceeding or matter which may be subject to indemnification or advancement of Expenses covered hereunder and shall include with such notice a description of
the nature of the Proceeding and a summary of the facts underlying the 

  
 3 

 
Proceeding, but the Indemnitee’s failure to so notify the Trust shall not disqualify the Indemnitee from the right, or otherwise affect in any manner any right of the Indemnitee, to
indemnification or the advance of Expenses under this Agreement unless the Trustee’s ability to defend in such proceeding or to obtain proceeds under any insurance policy is materially and adversely prejudiced thereby, and then only to the
extent the Trust is thereby actually prejudiced. 
 Section 3.2 Defense of Claims. The Trust shall have the right to defend the
Indemnitee in any Proceeding (except a Proceeding brought by the Indemnitee under Section 6.3 of this Agreement) which may give rise to indemnification hereunder; provided, however, that the Trust shall notify the
Indemnitee of any such decision to defend within 15 calendar days following receipt of notice of any such Proceeding under Section 3.1 above. Notwithstanding the foregoing sentence, if in a Proceeding to which the Indemnitee is a party
by reason of the Indemnitee’s Corporate Status, (a) the Indemnitee reasonably concludes, based upon an opinion of counsel approved by the Trust, which approval shall not be unreasonably withheld, that he or she may have separate defenses
or counterclaims to assert with respect to any issue which may not be consistent with other defendants in such Proceeding, (b) the Indemnitee reasonably concludes, based upon an opinion of counsel approved by the Trust, which approval shall not
be unreasonably withheld, that an actual or apparent conflict of interest or potential conflict of interest exists between the Indemnitee and the Trust, or (c) if the Trust fails to assume the defense of such Proceeding in a timely manner, the
Indemnitee shall be entitled to be represented by separate legal counsel of the Indemnitee’s choice, subject to the prior approval of the Trust, which shall not be unreasonably withheld, at the expense of the Trust. In addition, if the Trust
fails to comply with any of its obligations under this Agreement or in the event that the Trust or any other person takes any action to declare this Agreement void or unenforceable, or institutes any Proceeding to deny or to recover from the
Indemnitee the benefits intended to be provided to the Indemnitee hereunder, the Indemnitee shall have the right to retain counsel of the Indemnitee’s choice, subject to the prior approval of the Trust, which shall not be unreasonably withheld,
at the expense of the Trust (subject to Section 6.4 of this Agreement), to represent the Indemnitee in connection with any such matter. 

Section 3.3 Settlement of Claims. The Trust shall not, without the prior written consent of the Indemnitee, which shall not be
unreasonably withheld or delayed, consent to the entry of any judgment against the Indemnitee or enter into any settlement or compromise which (a) includes an admission of fault of the Indemnitee, (b) does not include, as an unconditional
term thereof, the full release of the Indemnitee from all Liability in respect of such Proceeding, which release shall be in form and substance reasonably satisfactory to the Indemnitee, or (c) would impose any Expense or Liability on
Indemnitee. 
 ARTICLE IV 

INDEMNIFICATION 
 Section
4.1 General. Upon the terms and subject to the limitations set forth in this Agreement, the Trust shall indemnify, and advance Expenses to, the Indemnitee (a) as provided in this Agreement and (b) to the maximum extent permitted by
Maryland law in effect on the Effective Date and as amended from time to time; provided, however, that no change in Maryland law shall have the effect of reducing the benefits available to the Indemnitee hereunder based on Maryland law
as in effect on the Effective Date. Subject to the limitations set forth in 

  
 4 

 
this Agreement, the rights of the Indemnitee provided in this Section 4.1 shall include, without limitation, the rights set forth in the other sections of this Agreement, and any
additional indemnification to which an Indemnitee may be entitled under the Trust Agreement, the Trust’s bylaws, as may be amended from time to time (the “Bylaws”), a resolution or other action by the Beneficiaries or Board of
Trustees, an agreement or otherwise, both as to action in an official capacity and as to action in another capacity while holding such office. 

Section 4.2 Standard for Indemnification. Subject to the limitations in Section 4.4, if, by reason of the Indemnitee’s
Corporate Status, the Indemnitee is, or is threatened to be, made a party to any Proceeding, the Indemnitee shall be indemnified, to the full extent permitted by Maryland law, against all Liabilities and all Expenses actually and reasonably incurred
by him or on his behalf in connection with any such Proceeding, including, without limitation, in connection with or arising out of any Proceeding based on any alleged breach of duty, neglect, error, misstatement, misleading statement, omission or
act of the Indemnitee in his capacity as a trustee or officer of the Trust. 
 Section 4.3 Indemnification for Expenses as Witness.
Subject to the limitations in Section 4.4, to the extent that the Indemnitee is or may be, by reason of the Indemnitee’s Corporate Status, made a witness or otherwise asked to participate in any Proceeding, whether instituted by the
Trust or any other party, and to which the Indemnitee is not a party, he shall be advanced all reasonable Expenses and indemnified against all Expenses actually and reasonably incurred by him or on his behalf in connection therewith within ten days
after the receipt by the Trust of a statement or statements requesting such advance or advances from time to time, whether prior to or after final disposition of such Proceeding. Such statement or statements shall reasonably evidence the Expenses
incurred by the Indemnitee. 
 Section 4.4 Specific Limitations on Indemnification. Notwithstanding anything in this Agreement to the
contrary, the Trust shall not be obligated under this Agreement to make any payment to the Indemnitee for indemnification with respect to any Proceeding: 

(a) for any loss or liability arising from an alleged violation of federal or state securities laws unless one or more of the
following conditions are met: (i) there has been a successful adjudication on the merits of each count involving alleged material securities law violations as to the Indemnitee; (ii) such claims have been dismissed with prejudice on the
merits by a court of competent jurisdiction as to the Indemnitee; or (iii) a court of competent jurisdiction approves a settlement of the claims against the Indemnitee and finds that indemnification of the settlement and the related costs
should be made, and the court considering the request for indemnification has been advised of the position of the Securities and Exchange Commission and of the published position of any state securities regulatory authority in which securities of
the Trust were offered or sold as to indemnification for violations of securities laws; or 
 (b) (i) that was by or in
the right of the Trust and in which the Indemnitee is adjudged to be liable to the Trust; or (ii) brought by the Indemnitee unless: (1) the Proceeding was brought to enforce indemnification under this Agreement, and then only to the extent
in accordance with and as authorized by Section 6.4 of this Agreement, or (2) the Trust Agreement, the Bylaws, a resolution or other action by the Beneficiaries or of the Board of Trustees or an agreement approved by the Board of
Trustees to which the Trust is a party expressly provide otherwise. 

  
 5 

 Section 4.5 Court-Ordered Indemnification. Subject to the limitations in Section 4.5,
a court of appropriate jurisdiction, upon application of the Indemnitee and such notice as the court shall require, may order indemnification in the following circumstances: 

(a) if it determines the Indemnitee is entitled to reimbursement under Section 12-403 of the Statutory Trust Act, the
court shall order indemnification, in which case the Indemnitee shall be entitled to recover the Expenses of securing such reimbursement; or 

(b) if it determines that the Indemnitee is fairly and reasonably entitled to indemnification in view of all the relevant
circumstances, whether or not the Indemnitee has met the standards of conduct as required under Section 12-403 of the Statutory Trust Act, the court may order such indemnification as the court shall deem proper. However, indemnification with
respect to any Proceeding by or in the right of the Trust shall be limited to Expenses. 
 ARTICLE V 

ADVANCEMENT OF EXPENSES 

If by reason of the Indemnitee’s Corporate Status, the Indemnitee is, or is threatened to be, made a party to any Proceeding, the Trust
shall, without requiring a preliminary determination of the Indemnitee’s ultimate entitlement to indemnification hereunder, advance all reasonable Expenses incurred by or on behalf of the Indemnitee in connection with such Proceeding within ten
days after the receipt by the Trust of a statement or statements requesting such advance or advances from time to time, whether prior to or after final disposition of such Proceeding. Such statement or statements shall reasonably evidence the
Expenses incurred by the Indemnitee and shall include or be preceded or accompanied by a written affirmation by the Indemnitee of the Indemnitee’s good faith belief that the standard of conduct necessary for indemnification by the Trust as
authorized by law and by this Agreement has been met and a written undertaking (the “Undertaking”) by or on behalf of the Indemnitee, in substantially the form attached hereto as Exhibit A or in such form as may be required
under applicable law as in effect at the time of the execution thereof, to reimburse the portion of any Expenses advanced to the Indemnitee, together with the Applicable Legal Rate of interest thereon, relating to claims, issues or matters in the
Proceeding as to which it is subsequently determined that the Indemnitee is not entitled to such indemnification. To the extent that Expenses advanced to the Indemnitee do not relate to a specific claim, issue or matter in the Proceeding, such
Expenses shall be allocated on a reasonable and proportionate basis. The undertaking required by this Article V shall be an unlimited general obligation by or on behalf of the Indemnitee and shall be accepted without reference to the
Indemnitee’s financial ability to repay such advanced Expenses and without any requirement to post security therefor. 

  
 6 

 ARTICLE VI 

PROCEDURE FOR PAYMENT OF LIABILITIES; 

DETERMINATION OF RIGHT TO INDEMNIFICATION 

Section 6.1 Procedure for Payment. To obtain indemnification for Liabilities under this Agreement, the Indemnitee shall submit to the
Trust a written request for payment, including with such request such documentation as is reasonably available to the Indemnitee and reasonably necessary to determine whether, and to what extent, the Indemnitee is entitled to indemnification and
payment hereunder. The Indemnitee may submit one or more such requests from time to time and at such time(s) as the Indemnitee deems appropriate in his sole discretion. The officer of the Trust receiving any such request from the Indemnitee,
promptly upon receipt of the request, shall advise the Board of Trustees, in writing, of such request. 
 Section 6.2 Determination of
Entitlement to Indemnification. Upon written request by the Indemnitee for indemnification pursuant to Section 6.1 above, a determination, if required by applicable law, with respect to the Indemnitee’s entitlement thereto shall
promptly be made in the specific case: (i) by the Board of Trustees by a majority vote of a quorum consisting of Disinterested Trustees or, if such a quorum cannot be obtained, then by a majority vote of a duly authorized committee of the Board
of Trustees consisting solely of one or more Disinterested Trustees, (ii) if Independent Counsel has been selected by the Board of Trustees in accordance with Maryland law and approved by the Indemnitee, which approval shall not be unreasonably
withheld, by Independent Counsel, in a written opinion to the Board of Trustees, a copy of which shall be delivered to the Indemnitee or (iii) if so directed by a majority of the members of the Board of Trustees, by the Beneficiaries of the
Trust. If it is so determined that the Indemnitee is entitled to indemnification, payment to the Indemnitee shall be made within ten days after such determination. The Indemnitee shall cooperate with the person, persons or entity making such
determination with respect to the Indemnitee’s entitlement to indemnification, including providing to such person, persons or entity upon reasonable advance request any documentation or information which is not privileged or otherwise protected
from disclosure and which is reasonably available to the Indemnitee and reasonably necessary to such determination in the discretion of the Board of Trustees or Independent Counsel if retained pursuant to clause (b)(ii) of this
Section 6.2. Any Expenses incurred by the Indemnitee in so cooperating with the person, persons or entity making such determination shall be borne by the Trust (irrespective of the determination as to the Indemnitee’s entitlement to
indemnification) and the Trust shall indemnify and hold the Indemnitee harmless therefrom. The Trust shall pay the reasonable fees and expenses of Independent Counsel, if one is appointed. 

Section 6.3 Remedies of Indemnitee. 

(a) If (i) a determination is made pursuant to Section 6.2 of this Agreement that the Indemnitee is not
entitled to indemnification under this Agreement, (ii) advance of Expenses is not timely made pursuant to Article V of this Agreement, (iii) no determination of entitlement to indemnification shall have been made pursuant to
Section 6.2 of this Agreement within 60 days after receipt by the Trust of the request for indemnification, (iv) payment of indemnification is not made pursuant to Section 4.3 of this Agreement within ten days after
receipt by the Trust of a written request therefor, or (v) payment of indemnification pursuant to any other section of this Agreement or the Trust Agreement or Bylaws is not made within ten days after a determination has been made that the
Indemnitee is entitled to indemnification, the Indemnitee shall be entitled to an adjudication in an appropriate court located in the State of Maryland, or in any other court of competent jurisdiction, of his entitlement to such indemnification or
advance of 

  
 7 

 
Expenses. Alternatively, the Indemnitee, at his option, may seek an award in arbitration to be conducted by a single arbitrator pursuant to the Commercial Arbitration Rules of the American
Arbitration Association. The Indemnitee shall commence a proceeding seeking an adjudication or an award in arbitration within 180 days following the date on which the Indemnitee first has the right to commence such proceeding pursuant to this
Section 6.3(a); provided, however, that the foregoing clause shall not apply to a proceeding brought by the Indemnitee to enforce his rights under Section 4.3 of this Agreement. Except as set forth herein, the
provisions of Maryland law (without regard to its conflicts of laws rules) shall apply to any such arbitration. The Trust shall not oppose the Indemnitee’s right to seek any such adjudication or award in arbitration. 

(b) In any judicial proceeding or arbitration commenced pursuant to this Section 6.3, the Indemnitee shall be
presumed to be entitled to indemnification or advance of Expenses, as the case may be, under this Agreement and the Trust shall have the burden of proving that the Indemnitee is not entitled to indemnification or advance of Expenses, as the case may
be. If the Indemnitee commences a judicial proceeding or arbitration pursuant to this Section 6.3, the Indemnitee shall not be required to reimburse the Trust for any advances pursuant to Article V of this Agreement until a final
determination is made with respect to the Indemnitee’s entitlement to indemnification (as to which all rights of appeal have been exhausted or lapsed). The Trust shall, to the fullest extent not prohibited by law, be precluded from asserting in
any judicial proceeding or arbitration commenced pursuant to this Section 6.3 that the procedures and presumptions of this Agreement are not valid, binding and enforceable and shall stipulate in any such court or before any such
arbitrator that the Trust is bound by all of the provisions of this Agreement. 
 (c) If a determination shall have been made
pursuant to Section 6.2 of this Agreement that the Indemnitee is entitled to indemnification, the Trust shall be bound by such determination in any judicial proceeding or arbitration commenced pursuant to this Section 6.3,
absent a misstatement by the Indemnitee of a material fact, or an omission of a material fact necessary to make the Indemnitee’s statement not materially misleading, in connection with the request for indemnification. 

Section 6.4 Expenses under this Agreement. In the event that the Indemnitee, pursuant to Section 6.3, seeks a judicial
adjudication of or an award in arbitration to enforce his rights under, or to recover damages for breach of, this Agreement, the Indemnitee shall be entitled to recover from the Trust, and shall be indemnified by the Trust for, any and all Expenses
actually and reasonably incurred by him in such judicial adjudication or arbitration. If it shall be determined in such judicial adjudication or arbitration that the Indemnitee is entitled to receive part but not all of the indemnification or
advance of Expenses sought, the Expenses incurred by the Indemnitee in connection with such judicial adjudication or arbitration shall be appropriately prorated. 

Section 6.5 Interest. Interest shall be paid by the Trust to the Indemnitee at the maximum rate allowed to be charged for judgments
under the Courts and Judicial Proceedings Article of the Annotated Code of Maryland for amounts which the Trust pays or is obligated to pay under Section 6.4 for the period commencing with the date on which the Indemnitee requests
indemnification, reimbursement or advance of any Expenses and ending on the date such payment is made to the Indemnitee by the Trust. 

  
 8 

 ARTICLE VII 

PRESUMPTIONS AND EFFECT OF CERTAIN PROCEEDINGS 

Section 7.1 Burden of Proof. In making a determination with respect to entitlement to indemnification hereunder, the person, persons,
entity or entities making such determination shall presume that the Indemnitee is entitled to indemnification under this Agreement if the Indemnitee has submitted a request for indemnification in accordance with Section 6.1 of this
Agreement, and the Trust shall have the burden of proof to overcome that presumption in connection with the making of any determination contrary to that presumption. 

Section 7.2 Effect of Other Proceedings. The termination of any Proceeding or of any claim, issue or matter therein, by judgment,
order, settlement or conviction, upon a plea of nolo contendere or its equivalent, or entry of an order of probation prior to judgment, does not create a presumption that the Indemnitee did not meet the requisite standard of conduct described herein
for indemnification. 
 Section 7.3 Actions of Others. The knowledge and/or actions, or failure to act, of any other trustee,
officer, agent or employee of the Trust or any other director, trustee, officer, partner, manager, managing member, fiduciary, employee or agent of any other foreign or domestic corporation, partnership, limited liability company, joint venture,
trust, other incorporated or unincorporated entity or enterprise or employee benefit plan shall not be imputed to the Indemnitee for purposes of determining the right to indemnification under this Agreement. 

ARTICLE VIII 
 INSURANCE;
COORDINATION OF PAYMENTS 
 The Trust will use its reasonable best efforts to acquire directors and officers liability insurance, on
terms and conditions deemed appropriate by the Board of Trustees, with the advice of counsel, covering the Indemnitee or any claim made against the Indemnitee by reason of his Corporate Status and covering the Trust for any indemnification or
advance of Expenses made by the Trust to the Indemnitee for any claims made against the Indemnitee by reason of his Corporate Status. Without in any way limiting any other obligation under this Agreement, the Trust shall indemnify the Indemnitee for
any payment by the Indemnitee arising out of the amount of any deductible or retention and the amount of any excess of the aggregate of all Liabilities and Expenses incurred by the Indemnitee in connection with a Proceeding over the coverage of any
insurance referred to in the previous sentence. The purchase, establishment and maintenance of any such insurance shall not in any way limit or affect the rights or obligations of the Trust or the Indemnitee under this Agreement except as expressly
provided herein, and the execution and delivery of this Agreement by the Trust and the Indemnitee shall not in any way limit or affect the rights or obligations of the Trust under any such insurance policies. If, at the time the Trust receives
notice from any source of a Proceeding to which the Indemnitee is a party or a participant (as a witness or otherwise), the Trust has director and officer liability insurance in effect, the Trust shall give prompt notice of such Proceeding to the
insurers in accordance with the procedures set forth in the respective policies. The Trust shall not be liable under this Agreement to make any payment of amounts otherwise indemnifiable or payable or reimbursable as Expenses hereunder if and to the
extent that the Indemnitee has otherwise actually received such payment under any insurance policy, contract, agreement or otherwise. 

  
 9 

 ARTICLE IX 

MISCELLANEOUS 
 Section 9.1
Non-Exclusivity. The rights of the Indemnitee hereunder shall not be deemed exclusive of any other rights to which the Indemnitee may at any time be entitled under any provision of law, the Trust Agreement, the Bylaws, any agreement,
resolution or other action by the Beneficiaries or of the Board of Trustees, or otherwise, and to the extent that during the term of this Agreement the rights of the then-existing trustees and officers of the Trust are more favorable to such
trustees or officers than the rights currently provided to the Indemnitee under this Agreement, the Indemnitee shall be entitled to the full benefits of such more favorable rights. Unless consented to in writing by the Indemnitee, no amendment,
alteration, rescission or replacement of this Agreement or any provision hereof which would in any way limit the benefits and protections afforded to an Indemnitee hereby shall be effective as to such Indemnitee with respect to any action or
inaction by such Indemnitee in the Indemnitee’s Corporate Status prior to such amendment, alteration, rescission or replacement, regardless of whether a claim with respect to such action or inaction is raised prior or subsequent to such
amendment, alteration, rescission or replacement. No right or remedy herein conferred is intended to be exclusive of any other right or remedy, and every other right or remedy shall be cumulative and in addition to every other right or remedy given
hereunder or now or hereafter existing at law or in equity or otherwise. The assertion of any right or remedy hereunder, or otherwise, shall not prohibit the concurrent assertion or employment of any other right or remedy. 

Section 9.2 Subrogation. In the event of any payment under this Agreement, the Trust shall be subrogated to the extent of such payment
to all of the rights of recovery of the Indemnitee, who shall execute all documents required and take all action necessary to secure such rights, including execution of such documents as are necessary to enable the Trust to bring suit to enforce
such rights. 
 Section 9.3 Notices. All notices, requests, demands and other communications hereunder shall be in writing and shall
be deemed to have been duly given (i) if delivered by hand or by courier and receipted for by the party to whom said notice or other communication shall have been directed at the time indicated on such receipt; (ii) if by facsimile at the
time shown on the confirmation of such facsimile transmission; or (iii) if by U.S. certified or registered mail, with postage prepaid, on the third business day after the date on which it is so mailed: 

If to the Indemnitee, to: 

                    
             
 518 17th street, 17th Floor 

Denver, CO 80202 

Facsimile No. (303) 869-4602 

  
 10 

 If to the Trust, to: 

DC Industrial Liquidating Trust 

518 17th street, 17th Floor 

Denver, CO 80202 

Attention: General Counsel 

Facsimile No. (303) 869-4602 

or to such other address as may have been furnished to the Indemnitee by the Trust or to the Trust by the Indemnitee, as the case may be. 

Section 9.4 Governing Law. The parties agree that this Agreement shall be governed by, and construed and enforced in accordance with,
the substantive laws of the State of Maryland, without application of the conflict of laws principles thereof. 
 Section 9.5 Binding
Effect. Except as otherwise provided in this Agreement, this Agreement shall be binding upon and be enforceable by the parties hereto and their respective successors and assigns (including any direct or indirect successor by purchase, merger,
consolidation or otherwise to all or substantially all of the business or assets of the Trust), shall continue to the extent provided in Article II above as to an Indemnitee who has ceased to be a trustee, officer, employee or agent of the Trust or
a director, trustee, officer, partner, manager, managing member, fiduciary, employee or agent of any other foreign or domestic corporation, partnership, limited liability company, joint venture, trust, other incorporated or unincorporated entity or
enterprise or employee benefit plan that such person is or was serving in such capacity at the request of the Trust, and shall inure to the benefit of the Indemnitee and his or her spouse, assigns, heirs, devisees, executors and administrators and
other legal representatives. The Trust shall require and cause any successor (whether direct or indirect by purchase, merger, consolidation or otherwise) to all or substantially all of the business and/or assets of the Trust, by written agreement in
form and substance satisfactory to the Indemnitee, expressly to assume and agree to perform this Agreement in the same manner and to the same extent that the Trust would be required to perform if no such succession had taken place. 

Section 9.6 Equitable Relief. The Trust and the Indemnitee agree herein that a monetary remedy for breach of this Agreement, at some
later date, may be inadequate, impracticable and difficult of proof, and further agree that such breach may cause the Indemnitee irreparable harm. Accordingly, the parties hereto agree that the Indemnitee may enforce this Agreement by seeking
injunctive relief and/or specific performance hereof, without any necessity of showing actual damage or irreparable harm and that by seeking injunctive relief and/or specific performance, the Indemnitee shall not be precluded from seeking or
obtaining any other relief to which he may be entitled. The Indemnitee shall further be entitled to such specific performance and injunctive relief, including temporary restraining orders, preliminary injunctions and permanent injunctions, without
the necessity of posting bonds or other undertakings in connection therewith. The Trust acknowledges that, in the absence of a waiver, a bond or undertaking may be required of the Indemnitee by a court, and the Trust hereby waives any such
requirement of such a bond or undertaking. 

  
 11 

 Section 9.7 Waiver. No termination, cancellation, modification, amendment, deletion,
addition or other change in this Agreement, or any provision hereof, or waiver of any right or remedy herein, shall be effective for any purpose unless specifically set forth in a writing signed by the party or parties to be bound thereby. The
waiver of any right or remedy with respect to any occurrence on one occasion shall not be deemed a waiver of such right or remedy with respect to such occurrence on any other occasion. 

Section 9.8 Entire Agreement. This Agreement, constitutes the entire agreement and understanding among the parties hereto in reference
to the subject matter hereof; provided, however, that the parties acknowledge and agree that the Trust Agreement and the Bylaws contains or may contain provisions on the subject matter hereof and that this Agreement is not intended to, and does not,
limit the rights or obligations of the parties hereto pursuant to such Trust Agreement or Bylaws. 
 Section 9.9 Titles. The titles
to the articles and sections of this Agreement are inserted for convenience of reference only and should not be deemed a part hereof or affect the construction or interpretation of any provisions hereof. 

Section 9.10 Invalidity of Provisions. If any provision or provisions of this Agreement shall be held to be invalid, illegal or
unenforceable for any reason whatsoever: (a) the validity, legality and enforceability of the remaining provisions of this Agreement (including, without limitation, each portion of any Article, Section, paragraph or sentence of this Agreement
containing any such provision held to be invalid, illegal or unenforceable that is not itself invalid, illegal or unenforceable) shall not in any way be affected or impaired thereby and shall remain enforceable to the fullest extent permitted by
law; (b) such provision or provisions shall be deemed reformed to the extent necessary to conform to applicable law and to give the maximum effect to the intent of the parties hereto; and (c) to the fullest extent possible, the provisions
of this Agreement (including, without limitation, each portion of any Article, Section, paragraph or sentence of this Agreement containing any such provision held to be invalid, illegal or unenforceable, that is not itself invalid, illegal or
unenforceable) shall be construed so as to give effect to the intent manifested thereby. 
 Section 9.11 Pronouns and Plurals.
Whenever the context may require, any pronoun used in this Agreement shall include the corresponding masculine, feminine or neuter forms, and the singular form of nouns, pronouns and verbs shall include the plural and vice versa. 

Section 9.12 Counterparts. This Agreement may be executed in one or more counterparts, each of which shall be deemed an original, but
all of which together constitute one agreement binding on all the parties hereto. One such counterpart signed by the party against whom enforceability is sought shall be sufficient to evidence the existence of this Agreement. 

[Signature Page Follows.] 

  
 12 

 IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the day and year first
above written. 
  

			
	DC INDUSTRIAL LIQUIDATING TRUST
		
	By:	 	 
		 	Name:
		 	Title:
	
	INDEMNITEE
	
	 

  
 13 

 EXHIBIT A 

FORM OF UNDERTAKING TO REPAY EXPENSES ADVANCED 

The Board of Trustees of DC Industrial Liquidating Trust. 
  

	Re:	Undertaking to Repay Expenses Advanced 

 Ladies and Gentlemen: 

This undertaking is being provided pursuant to that certain Indemnification Agreement dated the
         day of     , 2015, by and between DC Industrial Liquidating Trust and the undersigned Indemnitee (the “Indemnification Agreement”), pursuant to which I am entitled
to advancement of Expenses in connection with [Description of Proceeding] (the “Proceeding”). 
 Terms used herein and not
otherwise defined shall have the meanings specified in the Indemnification Agreement. 
 I am subject to the Proceeding by reason of my
Corporate Status or by reason of alleged actions or omissions by me in such capacity. In consideration of the advance of Expenses by the Trust for reasonable attorneys’ fees and related Expenses incurred by me in connection with the Proceeding
(the “Advanced Expenses”), I hereby agree that if, in connection with the Proceeding, it is established that I am not entitled to indemnification with respect to such Proceeding, then I shall promptly reimburse the portion of the Advanced
Expenses, together with the Applicable Legal Rate of interest thereon, relating to the claims, issues or matters in the Proceeding as to which the foregoing finding has been established. 

 

	
	 
	Signature
	
	 
	Name
	
	 
	Date

  
 14EX-10.6

 EXHIBIT 10.6 

CONSTRUCTION LOAN AGREEMENT 

among 
 REDLANDS DC LP, a
Delaware limited partnership, formerly known as IIT Redlands DC LP 
 CAJON DC LP, a Delaware limited partnership, formerly
known as IIT Cajon DC LP 
 MIAMI DC III LLC, a Delaware limited liability company, formerly known as IIT Miami DC III LLC

 MIAMI DC IV LLC, a Delaware limited liability company, formerly known as IIT Miami DC IV LLC 

MIAMI DC III LAND LLC, a Delaware limited liability company, formerly known as IIT Miami DC III Land LLC 

TAMARAC COMMERCE CENTER DC II LLC, a Delaware limited liability company, formerly known as IIT Tamarac Commerce Center II LLC 

TAMARAC COMMERCE CENTER DC III LLC, a Delaware limited liability company, formerly known as IIT Tamarac Commerce Center III LLC

 LEHIGH VALLEY CROSSING DC I LLC, a Delaware limited liability company, formerly known as IIT Lehigh Valley Crossing DC I LLC

 LEHIGH VALLEY CROSSING DC II LLC, a Delaware limited liability company, formerly known as IIT Lehigh Valley Crossing DC II
LLC 
 LEHIGH VALLEY CROSSING DC III LLC, a Delaware limited liability company, formerly known as IIT Lehigh Valley Crossing DC
III LLC 
 BLUEGRASS DC II LLC, a Delaware limited liability company, formerly known as IIT Bluegrass DC II LLC 

and 
 WELLS FARGO BANK,
NATIONAL ASSOCIATION 
 Dated as of November 4, 2015, 

  
 Loan No. 1015003 

 TABLE OF CONTENTS 

 

									
	 	 	 	 	 	  	Page	 
	 ARTICLE 1.
	 	 DEFINITIONS
	  	 	1	  
			
	 1.1
	 	 DEFINED TERMS
	  	 	1	  
			
	 ARTICLE 2.
	 	 LOAN
	  	 	13	  
			
	 2.1
	 	 LOAN
	  	 	13	  
			
	 2.2
	 	 PURPOSE
	  	 	13	  
			
	 2.3
	 	 GRANT OF SECURITY INTEREST IN REAL PROPERTY
	  	 	13	  
			
	 2.4
	 	 GRANT OF SECURITY INTEREST IN ACCOUNTS; APPLICATION OF FUNDS
	  	 	13	  
			
	 2.5
	 	 ADDITIONAL SECURITY INTEREST
	  	 	14	  
			
	 2.6
	 	 LOAN FEE
	  	 	14	  
			
	 2.7
	 	 LOAN DOCUMENTS
	  	 	14	  
			
	 2.8
	 	 EFFECTIVE DATE
	  	 	14	  
			
	 2.9
	 	 MATURITY DATE
	  	 	14	  
			
	 2.10
	 	 PREPAYMENT
	  	 	14	  
			
	 2.11
	 	 FULL REPAYMENT AND RECONVEYANCE, SATISFACTION OR RELEASE
	  	 	14	  
			
	 2.12
	 	 PARTIAL RELEASES
	  	 	14	  
			
	 2.13
	 	 OPTION TO EXTEND
	  	 	16	  
			
	 2.14
	 	 RECOURSE
	  	 	17	  
			
	 ARTICLE 3.
	 	 DISBURSEMENT
	  	 	17	  
			
	 3.1
	 	 CONDITIONS PRECEDENT
	  	 	17	  
			
	 3.2
	 	 ACCOUNT AND DISBURSEMENT AUTHORIZATION
	  	 	21	  
			
	 3.3
	 	 FUNDS TRANSFER DISBURSEMENTS
	  	 	22	  
			
	 3.4
	 	 LOAN DISBURSEMENTS
	  	 	22	  
			
	 3.5
	 	 REALLOCATIONS
	  	 	23	  
			
	 3.6
	 	 WITHHOLDING OF ADVANCES; RETENTION
	  	 	24	  
			
	 3.7
	 	 TENANT IMPROVEMENTS / LEASING COMMISSIONS
	  	 	24	  
			
	 3.8
	 	 INTEREST RESERVE ADVANCES
	  	 	25	  
			
	 3.9
	 	 LENDER’S OPTIONAL DISBURSEMENTS
	  	 	25	  
			
	 ARTICLE 4.
	 	 CONSTRUCTION
	  	 	25	  
			
	 4.1
	 	 COMMENCEMENT OF CONSTRUCTION
	  	 	25	  
			
	 4.2
	 	 COMPLETION OF CONSTRUCTION
	  	 	25	  
			
	 4.3
	 	 FORCE MAJEURE
	  	 	25	  
			
	 4.4
	 	 CONSTRUCTION AGREEMENT
	  	 	25	  
			
	 4.5
	 	 ARCHITECT’S AND DESIGN PROFESSIONAL’S AGREEMENT
	  	 	26	  
			
	 4.6
	 	 PLANS AND SPECIFICATIONS
	  	 	26	  

  

					
		  	-i-	  	Loan No. 1015003

 TABLE OF CONTENTS 

(Continued) 
  

									
	 	 	 	 	 	  	Page	 
			
	 4.7
	 	 CONTRACTOR/CONSTRUCTION INFORMATION
	  	 	27	  
			
	 4.8
	 	 PROHIBITED CONTRACTS
	  	 	27	  
			
	 4.9
	 	 LIENS AND NOTICES
	  	 	27	  
			
	 4.10
	 	 CONSTRUCTION RESPONSIBILITIES
	  	 	28	  
			
	 4.11
	 	 ASSESSMENTS AND COMMUNITY FACILITIES DISTRICTS
	  	 	28	  
			
	 4.12
	 	 DELAY
	  	 	28	  
			
	 4.13
	 	 INSPECTIONS
	  	 	28	  
			
	 4.14
	 	 SURVEYS
	  	 	29	  
			
	 4.15
	 	 IN BALANCE PAYMENTS
	  	 	29	  
			
	 ARTICLE 5.
	 	 INSURANCE
	  	 	29	  
			
	 5.1
	 	 TITLE INSURANCE
	  	 	29	  
			
	 5.2
	 	 PROPERTY INSURANCE
	  	 	29	  
			
	 5.3
	 	 FLOOD HAZARD INSURANCE
	  	 	29	  
			
	 5.4
	 	 LIABILITY INSURANCE
	  	 	29	  
			
	 5.5
	 	 OTHER COVERAGE
	  	 	30	  
			
	 5.6
	 	 GENERAL
	  	 	30	  
			
	 5.7
	 	 COLLATERAL PROTECTION INSURANCE NOTICE
	  	 	30	  
			
	 ARTICLE 6.
	 	 REPRESENTATIONS AND WARRANTIES
	  	 	30	  
			
	 6.1
	 	 AUTHORITY/ENFORCEABILITY
	  	 	30	  
			
	 6.2
	 	 BINDING OBLIGATIONS
	  	 	30	  
			
	 6.3
	 	 FORMATION AND ORGANIZATIONAL DOCUMENTS
	  	 	30	  
			
	 6.4
	 	 NO VIOLATION
	  	 	31	  
			
	 6.5
	 	 COMPLIANCE WITH LAWS; USE
	  	 	31	  
			
	 6.6
	 	 LITIGATION
	  	 	31	  
			
	 6.7
	 	 FINANCIAL CONDITION
	  	 	31	  
			
	 6.8
	 	 NO MATERIAL ADVERSE CHANGE
	  	 	31	  
			
	 6.9
	 	 LOAN PROCEEDS AND ADEQUACY
	  	 	32	  
			
	 6.10
	 	 ACCURACY
	  	 	32	  
			
	 6.11
	 	 TAX LIABILITY
	  	 	32	  
			
	 6.12
	 	 UTILITIES
	  	 	32	  
			
	 6.13
	 	 COMPLIANCE
	  	 	32	  
			
	 6.14
	 	 AMERICANS WITH DISABILITIES ACT COMPLIANCE
	  	 	32	  
			
	 6.15
	 	 BUSINESS LOAN
	  	 	32	  
			
	 6.16
	 	 TAX SHELTER REGULATIONS
	  	 	32	  
			
	 6.17
	 	 FULL FORCE AND EFFECT
	  	 	32	  

  

					
		  	-ii-	  	Loan No. 1015003

 TABLE OF CONTENTS 

(Continued) 
  

									
	 	 	 	 	 	  	Page	 
			
	 6.18
	 	 NO SUBORDINATION
	  	 	32	  
			
	 6.19
	 	 PERMITS; FRANCHISES
	  	 	33	  
			
	 6.20
	 	 OTHER OBLIGATIONS
	  	 	33	  
			
	 6.21
	 	 LEASES
	  	 	33	  
			
	 6.22
	 	 MATERIAL CONTRACTS
	  	 	33	  
			
	 6.23
	 	 SANCTIONS
	  	 	33	  
			
	 6.24
	 	 PROJECT INFORMATION
	  	 	33	  
			
	 6.25
	 	 REAFFIRMATION AND SURVIVAL OF REPRESENTATIONS AND WARRANTIES
	  	 	33	  
			
	 ARTICLE 7.
	 	 REPRESENTATIONS, WARRANTIES AND COVENANTS REGARDING SPECIAL PURPOSE ENTITY STATUS
	  	 	34	  
			
	 7.1
	 	 REPRESENTATIONS, WARRANTIES AND COVENANTS REGARDING SPECIAL PURPOSE ENTITY (“SPE”) STATUS
	  	 	34	  
			
	 ARTICLE 8.
	 	 HAZARDOUS MATERIALS
	  	 	35	  
			
	 8.1
	 	 HAZARDOUS MATERIALS INDEMNITY AGREEMENT
	  	 	35	  
			
	 ARTICLE 9.
	 	 COVENANTS OF BORROWERs
	  	 	35	  
			
	 9.1
	 	 EXPENSES
	  	 	35	  
			
	 9.2
	 	 ERISA COMPLIANCE
	  	 	36	  
			
	 9.3
	 	 LEASING
	  	 	36	  
			
	 9.4
	 	 APPROVAL OF LEASES
	  	 	36	  
			
	 9.5
	 	 SNDA Delivery
	  	 	37	  
			
	 9.6
	 	 DISTRIBUTIONS
	  	 	37	  
			
	 9.7
	 	 SUBDIVISION MAPS
	  	 	37	  
			
	 9.8
	 	 SECURITY DEPOSITS
	  	 	37	  
			
	 9.9
	 	 GOVERNMENTAL COMPLIANCE
	  	 	38	  
			
	 9.10
	 	 ASSIGNMENT
	  	 	38	  
			
	 9.11
	 	 MANAGEMENT AND LEASING OF PROPERTIES
	  	 	38	  
			
	 9.12
	 	 SUBORDINATION OF MANAGEMENT AGREEMENT
	  	 	38	  
			
	 9.13
	 	 SUBORDINATION OF LISTING AGREEMENT
	  	 	38	  
			
	 9.14
	 	 MANAGER
	  	 	38	  
			
	 9.15
	 	 DEVELOPMENT OF PROPERTIES
	  	 	39	  
			
	 9.16
	 	 SWAP AGREEMENTS
	  	 	39	  
			
	 9.17
	 	 SUBORDINATION OF DEVELOPMENT AGREEMENT
	  	 	39	  
			
	 9.18
	 	 PROPERTY TRANSFERS
	  	 	39	  
			
	 9.19
	 	 EQUITY TRANSFERS
	  	 	39	  
			
	 9.20
	 	 CERTIFICATES OF OWNERSHIP    
	  	 	40	  

  

					
		  	-iii-	  	Loan No. 1015003

 TABLE OF CONTENTS 

(Continued) 
  

									
	 	 	 	 	 	  	Page	 
			
	 9.21
	 	 ACCOUNTS AND CASH FLOW
	  	 	40	  
			
	 9.22
	 	 ADDITIONAL DEBT AND SEPARATE GUARANTY
	  	 	41	  
			
	 9.23
	 	 EXISTENCE
	  	 	41	  
			
	 9.24
	 	 TAXES AND OTHER LIABILITIES
	  	 	41	  
			
	 9.25
	 	 NOTICE
	  	 	41	  
			
	 9.26
	 	 ACTIONS TO MAINTAIN PROPERTY
	  	 	42	  
			
	 9.27
	 	 MATERIAL CONTRACTS
	  	 	42	  
			
	 9.28
	 	 INSURANCE
	  	 	42	  
			
	 9.29
	 	 FURTHER ASSURANCES
	  	 	42	  
			
	 ARTICLE 10.
	 	 REPORTING COVENANTS
	  	 	42	  
			
	 10.1
	 	 FINANCIAL INFORMATION
	  	 	42	  
			
	 10.2
	 	 TAX RETURNS
	  	 	43	  
			
	 10.3
	 	 BOOKS AND RECORDS
	  	 	43	  
			
	 10.4
	 	 REPORTS
	  	 	43	  
			
	 10.5
	 	 LEASING REPORTS
	  	 	43	  
			
	 10.6
	 	 OPERATING STATEMENTS FOR PROPERTIES
	  	 	43	  
			
	 10.7
	 	 PROJECTED FINANCIAL STATEMENTS AND OTHER INFORMATION
	  	 	43	  
			
	 ARTICLE 11.
	 	 DEFAULTS AND REMEDIES
	  	 	43	  
			
	 11.1
	 	 DEFAULT
	  	 	43	  
			
	 11.2
	 	 ACCELERATION UPON DEFAULT; REMEDIES
	  	 	46	  
			
	 11.3
	 	 DISBURSEMENTS TO THIRD PARTIES
	  	 	46	  
			
	 11.4
	 	 LENDER’S COMPLETION OF CONSTRUCTION
	  	 	46	  
			
	 11.5
	 	 LENDER’S RIGHT TO STOP CONSTRUCTION
	  	 	47	  
			
	 11.6
	 	 SET OFF
	  	 	47	  
			
	 11.7
	 	 RIGHTS CUMULATIVE, NO WAIVER
	  	 	47	  
			
	 ARTICLE 12.
	 	 MISCELLANEOUS PROVISIONS
	  	 	47	  
			
	 12.1
	 	 INDEMNITY
	  	 	47	  
			
	 12.2
	 	 FORM OF DOCUMENTS
	  	 	48	  
			
	 12.3
	 	 NO THIRD PARTIES BENEFITED
	  	 	48	  
			
	 12.4
	 	 NOTICES
	  	 	48	  
			
	 12.5
	 	 ATTORNEY-IN-FACT
	  	 	49	  
			
	 12.6
	 	 ACTIONS
	  	 	49	  
			
	 12.7
	 	 RIGHT OF CONTEST
	  	 	49	  
			
	 12.8
	 	 RELATIONSHIP OF PARTIES
	  	 	49	  
			
	 12.9
	 	 DELAY OUTSIDE LENDER’S CONTROL
	  	 	49	  

  

					
		  	-iv-	  	Loan No. 1015003

 TABLE OF CONTENTS 

(Continued) 
  

									
	 	 	 	 	 	  	Page	 
			
	 12.10
	 	 ATTORNEYS’ FEES AND EXPENSES; ENFORCEMENT
	  	 	49	  
			
	 12.11
	 	 IMMEDIATELY AVAILABLE FUNDS
	  	 	50	  
			
	 12.12
	 	 LENDER’S CONSENT
	  	 	50	  
			
	 12.13
	 	 LOAN SALES AND PARTICIPATION; DISCLOSURE OF INFORMATION
	  	 	50	  
			
	 12.14
	 	 CAPITAL ADEQUACY
	  	 	50	  
			
	 12.15
	 	 LENDER’S AGENTS
	  	 	51	  
			
	 12.16
	 	 TAX SERVICE
	  	 	51	  
			
	 12.17
	 	 WAIVER OF RIGHT TO TRIAL BY JURY
	  	 	51	  
			
	 12.18
	 	 SEVERABILITY
	  	 	51	  
			
	 12.19
	 	 HEIRS, SUCCESSORS AND ASSIGNS
	  	 	51	  
			
	 12.20
	 	 TIME
	  	 	51	  
			
	 12.21
	 	 HEADINGS
	  	 	51	  
			
	 12.22
	 	 GOVERNING LAW AND CONSENT TO JURISDICTION
	  	 	52	  
			
	 12.23
	 	 GOVERNMENTAL COMPLIANCE
	  	 	52	  
			
	 12.24
	 	 INTENTIONALLY DELETED
	  	 	52	  
			
	 12.25
	 	 COUNTERPARTS
	  	 	52	  
			
	 12.26
	 	 IIT
	  	 	52	  
			
	 12.27
	 	 INTEGRATION; INTERPRETATION
	  	 	52	  
			
	 12.28
	 	 TAX SHELTER MATTERS
	  	 	52	  
			
	 12.29
	 	 NO WAIVER
	  	 	53	  
			
	 12.30
	 	 JOINT AND SEVERAL LIABILITY
	  	 	53	  
			
	 12.31
	 	 ELECTRONIC TRANSMISSION OF DATA
	  	 	53	  
			
	 12.32
	 	 POWERS OF ATTORNEY
	  	 	53	  
			
	 12.33
	 	 RULES OF CONSTRUCTION
	  	 	53	  
			
	 12.34
	 	 USE OF SINGULAR AND PLURAL; GENDER
	  	 	54	  
			
	 12.35
	 	 EXHIBITS, SCHEDULES AND RIDERS
	  	 	54	  
			
	 12.36
	 	 INCONSISTENCIES
	  	 	54	  
			
	 12.37
	 	 ADVERTISING; SIGNS
	  	 	54	  
			
	 12.38
	 	 SPECIAL REPRESENTATIONS, CONSENTS AND WAIVERS CONCERNING CO-BORROWERS
	  	 	54	  
				
	SCHEDULE 1	 	-	 	BORROWERS AND PROPERTIES	  			
	SCHEDULE 2	 	-	 	BANK OF AMERICA LETTERS OF CREDIT	  			
	SCHEDULE 2.10	 	-	 	ALLOCATED LOAN AMOUNTS	  			
	SCHEDULE 6.3	 	-	 	ORGANIZATIONAL CHART	  			
	SCHEDULE 6.6	 	-	 	LITIGATION	  			
	SCHEDULE 6.22	 	-	 	LEASES	  			
	EXHIBIT A	 	-	 	PROPERTIES	  			

  

					
		  	-v-	  	Loan No. 1015003

 TABLE OF CONTENTS 

(Continued) 
  

							
	 	 	 	 	 	  	Page
	EXHIBIT A-1	 	-	 	REDLANDS PROPERTY	  	
	EXHIBIT A-2	 	-	 	CAJON PROPERTY	  	
	EXHIBIT A-3	 	-	 	MIAMI III PROPERTY	  	
	EXHIBIT A-4	 	-	 	MIAMI IV PROPERTY	  	
	EXHIBIT A-5	 	-	 	MIAMI III LAND PROPERTY	  	
	EXHIBIT A-6	 	-	 	TAMARAC COMMERCE CENTER II PROPERTY	  	
	EXHIBIT A-7	 	-	 	TAMARAC COMMERCE CENTER III PROPERTY	  	
	EXHIBIT A-8	 	-	 	LEHIGH VALLEY I PROPERTY	  	
	EXHIBIT A-9	 	-	 	LEHIGH VALLEY II PROPERTY	  	
	EXHIBIT A-10	 	-	 	LEHIGH VALLEY III PROPERTY	  	
	EXHIBIT A-11	 	-	 	BLUEGRASS II PROPERTY	  	
	EXHIBIT B	 	-	 	DOCUMENTS	  	
	EXHIBIT C	 	-	 	LOAN BUDGET	  	
	EXHIBIT D	 	-	 	DISBURSEMENT PLAN	  	
	EXHIBIT E	 	-	 	DISBURSEMENT INSTRUCTION AGREEMENT	  	
	EXHIBIT F	 	-	 	DESIGN PROFESSIONAL’S CONSENT FORM	  	
	EXHIBIT G	 	-	 	CONTRACTOR’S CONSENT FORM	  	
	EXHIBIT H	 	-	 	OPTION TO EXTEND REQUEST LETTER FROM BORROWER	  	
	EXHIBIT I	 	-	 	PROPERTY LEVEL BUDGET	  	

  

					
		  	-vi-	  	Loan No. 1015003

 CONSTRUCTION LOAN AGREEMENT 

This CONSTRUCTION LOAN AGREEMENT (“Agreement”) is dated as of November 4, 2015, by and among REDLANDS DC
LP, a Delaware limited partnership, formerly known as IIT Redlands DC LP, CAJON DC LP, a Delaware limited partnership, formerly known as IIT Cajon DC LP, MIAMI DC III LLC, a Delaware limited liability company, formerly known as IIT
Miami DC III LLC, MIAMI DC IV LLC, a Delaware limited liability company, formerly known as IIT Miami DC IV LLC, MIAMI DC III LAND LLC, a Delaware limited liability company, formerly known as IIT Miami DC III Land LLC, TAMARAC
COMMERCE CENTER DC II LLC, a Delaware limited liability company, formerly known as IIT Tamarac Commerce Center II LLC, TAMARAC COMMERCE CENTER DC III LLC, a Delaware limited liability company, formerly known as IIT Tamarac Commerce Center
III LLC, LEHIGH VALLEY CROSSING DC I LLC, a Delaware limited liability company, formerly known as IIT Lehigh Valley Crossing DC I LLC, LEHIGH VALLEY CROSSING DC II LLC, a Delaware limited liability company, formerly known as IIT Lehigh
Valley Crossing DC II LLC, LEHIGH VALLEY CROSSING DC III LLC, a Delaware limited liability company, formerly known as IIT Lehigh Valley Crossing DC III LLC, BLUEGRASS DC II LLC, a Delaware limited liability company, formerly known as
IIT Bluegrass DC II LLC (each, a “Borrower” and collectively, the “Borrowers”), jointly and severally, and WELLS FARGO BANK, NATIONAL ASSOCIATION (“Lender”). 

R E C I T A L S 
  

	 	A.	Borrowers desire to borrow from Lender, and Lender agrees to loan to Borrowers, the extension of credit for which provision is made herein. 

 

	 	B.	Borrowers collectively own that certain portfolio of real property listed on Schedule 1 and described more particularly in Exhibit A attached hereto, together with all buildings, appurtenances, fixtures, and
improvements now or hereafter located thereon, including, without limitation, the Construction Improvements defined herein (each, a “Property” and collectively, the “Properties”). 

 

	 	C.	Borrowers have requested that proceeds of the loan be used for, among other things, (i) completing the construction of Bluegrass Valley II Property and the Lehigh Valley II Property (collectively, the
“Construction Improvements”), (ii) the General Uses (as hereinafter defined) and (iii) the Closing Date Uses (as hereinafter defined). 

NOW, THEREFORE, Borrower and Lender agree as follows: 

ARTICLE 1. DEFINITIONS 
  

	1.1	DEFINED TERMS. The following capitalized terms generally used in this Agreement shall have the meanings defined or referenced below. Certain other capitalized terms used only in specific sections of this
Agreement are defined in such sections. 

 “Account Funds” – means all sums now or hereafter on deposit
in or payable or withdrawable from any of the Accounts. 
 “Accounts” – means the Collection Account, Lockbox Account,
Operating Account, Security Deposit Account, any subaccounts created thereunder and all other accounts with Lender created hereunder and under the other Loan Documents from time to time. 

“ADA” - means the Americans with Disabilities Act, 42 U.S.C.
§§ 12101, et. seq., as now or hereafter amended or modified. 

  

					
		 	1	  	Loan No. 1015003

 “Advisory Agreement” – mean that certain Management Services Agreement
dated November 4, 2015, by and among Holdco, the Trust and DC Liquidating Trust Advisor LLC. 
 “Affiliate” or
“affiliate” - means, as to any specified Person, (a) any Person that directly or indirectly through one or more intermediaries Controls or is Controlled by or is under common Control with
such Person, (b) any Person owning or Controlling forty nine percent (49%) or more of the outstanding voting securities of or other ownership interests in such Person, (c) if such Person is an individual, an entity for which such
Person directly or indirectly acts as an officer, director, partner, owner or member, (d) any entity in which such Person (together with the members of his family if the Person in question is an individual) owns, directly or indirectly through
one or more intermediaries an interest in any class of stock (or other beneficial interest in such entity) of forty-nine percent (49%) or more, or (e) with respect to any Obligor, any other Obligor. 

“Agreement” - has the meaning ascribed to such term in the preamble hereto. 

“Allocated Loan Amount” – means the amount of the Loan allocated to each Property as set forth on Schedule 2.10.
Upon any partial prepayment of the principal amount of the Loan pursuant to the terms of this Agreement, such prepaid amounts shall thereafter be allocated by Lender among the Properties pro rata (based on the Allocated Loan Amounts set forth for
each Property) and shall reduce the same accordingly; provided that, upon a Partial Release pursuant to Section 2.12 or in connection with the application of insurance or condemnation proceeds, such prepaid amount shall first be applied
to reduce in its entirety the Allocated Loan Amount with respect to the applicable Property released or subject to such insurance or condemnation proceeds, and then allocated pro rata among the remaining Properties. 

“Applicable Law” – means all constitutions, statutes, rules, regulations and orders of any Governmental Authority,
including all orders and decrees of all courts, tribunals and arbitrators applicable to each Borrower, Guarantor, each Property, or Lender, as the context requires. 

“Appraisal” – means a written appraisal regarding a Property prepared in conformance with the requirements of FIRREA, as
well as any other applicable rules and/or regulations from any and all applicable Governmental Authorities. 
 “Approved Lease
Form” – means, subject to Section 9.4, the standard lease form approved by Lender prior to the Effective Date, as amended and approved by Lender from time to time thereafter. 

“Approved Leases” - means any Lease that has been approved by Lender, such approval
not to be unreasonably withheld, conditioned or delayed. A Lease shall be deemed, without Lender’s express approval thereof, to be an Approved Lease (a “Deemed Approved Lease”) if it is either: (i) a Lease existing as of
the Effective Date, or (ii) satisfies the following requirements: (A) (1) it is on the Approved Lease Form without any material changes, including, without limitation, any material changes to the form estoppel, subordination, attornment
and mortgagee protection provisions contained within the Approved Lease Form, or (2) it is on a lease form required by a national or other credit tenant provided that such form does not include any purchase option or expansion option rights in
favor of the applicable tenant; (B) the tenant subject to such Lease is not an Affiliate of any Borrower or Guarantor; (C) the leased premises under such Lease is less than the greater of (1) 25,000 net rentable square feet and
(2) twenty-five percent (25%) of the net rentable square feet of the building in which such premises is located; (D) such Lease has a lease term of at least thirty-six (36) months; and (E) such Lease has a Net Effective Rent
at ninety percent (90%) or more of the Net Effective Rent used in the financial proforma contained in the Appraisal used by Lender in approving this Loan. Notwithstanding the foregoing, any Lease (including any renewals or material
modifications or amendments) for all or any part of the Redlands Property and/or Cajon Property shall in all cases require the consent of Lender. 

  

					
		 	2	  	Loan No. 1015003

 “Architect” – means, collectively, the Bluegrass Valley II Architect and
the Lehigh Valley II Architect. 
 “Architect’s Agreement” – means, collectively, (i) with respect to the
Bluegrass Valley II Property, the agreement for architectural services, dated February 10, 2015, by and between the Bluegrass Valley II Borrower and the Bluegrass Valley II Architect and (ii) with respect to the Lehigh Valley II Property,
the agreement for architectural services to be entered into by and between the Lehigh Valley II Borrower and the Lehigh Valley II Architect. 

“Bank of America Letters of Credit” – means one or more letters of credits or similar instructions currently issued by
Bank of America, N.A. upon the application of a Borrower, upon which a Borrower is an account party or for which a Borrower is in any way liable, which letters of credit are more particularly set forth on Schedule 2. 

“Bankruptcy Code” - means the Bankruptcy Reform Act of 1978 (11 U.S.C. § 101-1330) as now or hereafter amended or recodified. 
 “Bluegrass Valley II
Architect” – Randall-Paulson Architects, Incorporated. 
 “Bluegrass Valley II Borrower” – the Borrower
that owns the Bluegrass Valley II Property. 
 “Bluegrass Valley II General Contractor” – The Conlan Company. 

“Bluegrass Valley II Property” – means the Property more particularly described on Exhibit A-11 attached hereto as
being the “Bluegrass Valley II Property.” 
 “Borrower” – has the meaning ascribed to such term in the
preamble hereto. 
 “Borrowers Cash Management Agreement” – means the Cash Management Agreement between Borrowers and
Lender, dated as of the date hereof (as the same may be amended, restated, supplemented or modified from time to time). 
 “Borrowing
Group” - means, individually and collectively: (a) each Borrower, (b) the Guarantor, and (c) any officer, director or other person or entity acting on behalf of any Borrower or Guarantor with respect to the Loan. 

“Borrowers’ Equity Requirement” - means the equity contribution by Borrowers in
an amount no less than One Hundred Four Million and No/100ths Dollars ($104,000,000.00). 
 “Borrowers’ Funds” - means all funds of Borrower deposited in the Borrowers’ Funds subaccount of the Guarantor Reserve Account pursuant to the terms of this Agreement. 

“Business Day” - means any day, except a Saturday, Sunday or any other day on which
commercial banks in New York, New York are authorized or required by law to close. Unless specifically referenced in this Agreement as a Business Day, all references to “days” shall be to calendar days. 

“Cajon Property” – means the Property more particularly described on Exhibit A-2 attached hereto as being the
“Cajon Property.” 
 “Close-Out Agreements” – means any construction related agreements entered into by any
Borrower (other than the Construction Borrowers) for which the work has been completed but for which all payments have not been made as of the Effective Date. 

  

					
		 	3	  	Loan No. 1015003

 “Closing Date Uses” – shall mean the following purposes for which the Loan
proceeds may be used in connection with the closing of the Loan: (i) the Spin-Off, (ii) certain fees, costs and expenses agreed to by Lender in connection with the closing of the Loan, (iii) the Special Distribution, (iv) funding
the Guarantor Reserve Account and Master Operating Account in accordance with the terms of this Agreement, and (v) funding the L/C Cash Collateral Amount into the L/C Cash Collateral Account. 

“Collateral” – has the meaning ascribed to such term in the applicable Security Instrument. 

“Collection Account” – shall have the meaning given to such term in the Borrowers Cash Management Agreement. 

“Commitment Amount” – has the meaning ascribed to such term in Section 2.1, as adjusted pursuant to the terms
of this Agreement. 
 “Complete”, “Completed” or “Completion” - means completion of the
Construction Improvements, which shall be deemed to have occurred, with respect to such portion thereof upon: (i) Lender’s receipt of a written statement or certificate executed by the applicable Architect designated or shown on the
applicable Plans and Specifications approved by Lender certifying, without qualification or exception (other than punchlist items), that the applicable portion of the shell Construction Improvements are completed; (ii) Lender’s receipt of
all temporary or permanent certificates of occupancy or other comparable governmental approvals which are required for the applicable portion of the Construction Improvements by the local government agency having jurisdiction and authority to issue
such certificates of occupancy or other approvals; and (iii) the expiration of the statutory period(s) within which valid mechanic’s liens, materialman’s liens affidavits or notices may be recorded and/or served by reason of the
construction or renovation of the applicable portion of the Construction Improvements, or, alternatively, Lender’s receipt of valid, unconditional releases thereof from the applicable General Contractor and all Material Subcontractors. 

“Constituent Entity” – means any (i) member of any Borrower or Guarantor, and (ii) corporation, limited
liability company, partnership, trust, or other type of business organization included in the signature for any Borrower or Guarantor that is contained in any of the Loan Documents or where consent, approval or other authorization is required for
any Borrower’s or Guarantor’s execution of any Loan Documents. 
 “Construction Agreement” – means, as
applicable: (i) with respect to the Bluegrass Valley II Property, the agreement for construction services, dated August 18, 2015, by and between the Bluegrass Valley II Borrower and the Bluegrass Valley II General Contractor, (ii) and
with respect to the Lehigh Valley II Property, the agreement for construction services to be entered into by and between the Lehigh Valley II Borrower and the Lehigh Valley II General Contractor and (iii) any other construction agreements
related to the construction of Tenant Improvements between Borrower, as the owner, and any Contractor. 
 “Construction
Borrowers” – means the applicable Borrower that owns each of the Bluegrass Valley II Property and Lehigh Valley II Property. 

“Construction Improvements” – has the meaning ascribed to such term in the Recitals. 

“Construction Property” – shall mean each of the Bluegrass Valley II Property and the Lehigh Valley II Property. 

“Construction Properties” – shall mean, collectively, the Bluegrass Valley II Property and the Lehigh Valley II Property.

  

					
		 	4	  	Loan No. 1015003

 “Contractor” - means a contractor,
acceptable to Lender, who will construct all or any portion of the Tenant Improvements. 
 “Control” – means, with
respect to any Person, (i) the ownership, directly or indirectly, of at least ten percent (10%) of the common equity interests in such Person and (ii) the possession, directly or indirectly, of the power to direct or cause the
direction of the management (including the day-to-day management decisions) and policies of such Person whether through the ability to exercise voting power, by contract or otherwise. 

“Deemed Approved Lease” - has the meaning ascribed to such term in the definition of
“Approved Leases” in Section 1.1. 
 “Default” - has the
meaning ascribed to such term in Section 11.1. 
 “DERM” - has the
meaning ascribed to such term in Section 2.13(k). 
 “Design Professional”
- means any architect or engineer which prepares any of the Plans and Specifications for any portion of the Construction Improvements or Tenant Improvements. 

“Design Professional’s Agreement” - means each and every agreement by and between
Borrower and each Design Professional. 
 “Determination Date” - means the last day of each calendar month during the term
of the Loan. 
 “Developer” - means the Person engaged by each applicable Borrower,
and who shall be acceptable to Lender, for the development of each Property. 
 “Development Agreement” – means each
development agreement by and between each applicable Borrower and a Developer, the form and substance of which shall be acceptable to Lender. 

“Development Agreement Subordination” – means a document or documents, in form and substance satisfactory to Lender,
pursuant to which Developer acknowledges and agrees to the collateral assignment of the applicable Development Agreement to Lender and subordinates the Development Agreement to the applicable Security Instrument on terms and conditions reasonably
satisfactory to Lender. 
 “Disbursement Instruction Agreement” – means a Disbursement Instruction Agreement in the
form attached hereto as Exhibit E, or on such other form as Lender and Borrower may agree upon from time to time. 

“Dollars” or “$” – means the lawful currency of the United States of America. 

“Effective Date” - means the earlier of (i) the date that the Loan proceeds are
first released to, or for the benefit of, Borrowers, and (ii) the date the Security Instruments are recorded in each of the real property records of the counties where the Properties is located. 

“Embargoed Person” - means any person, entity or country which is a sanctioned person, entity or country under U.S. law,
including but not limited to, the International Emergency Economic Powers Act, 50 U.S.C. §§ 1701 et seq., The Trading with the Enemy Act, 50 U.S.C. App. 1 et seq., and any Executive Orders or regulations promulgated thereunder (including
regulations administered by OFAC and the Specially Designated Nationals List maintained by OFAC) with the result that the investment in Borrower (whether directly or indirectly), is prohibited by, or the Loan made by Lender is in violation of, any
applicable federal, state, county, municipal and other governmental statutes, laws, rules, orders, regulations, ordinances, judgments, decrees and injunctions affecting Borrower, the Property, or any part thereof, whether now or hereafter enacted
and in force. 

  

					
		 	5	  	Loan No. 1015003

 “Estimated Loan Amount Outstanding” – means if (i) the Projected Net
Operating Income used in calculating the Outstanding Amount Debt Yield contains the rental income from tenants under Approved Leases who are not yet in occupancy of the leased premises and (ii) the Loan Budget contains unfunded allocations of
tenant allowance and leasing commissions attributable to such Approved Leases which, in Lender’s discretion is anticipated to be disbursed pursuant to this Agreement, then Estimated Loan Amount Outstanding shall be calculated by (i) adding
an amount equal to the unfunded allocations of tenant allowance and leasing commissions attributable to such Approved Leases for further disbursements in accordance with the Loan Budget to (ii) the then actual outstanding principal balance of
the Note. 
 “ERISA” – has the meaning ascribed thereto in Section 9.2. 

“Extended Maturity Date” - means November 3, 2018. 

“Fee Letter” – means that certain letter agreement between DC Liquidating Assets Holdco LLC and Lender, dated
August 24, 2015. 
 “FIRREA” – means the Financial Institutions Reform, Recovery, and Enforcement Act of 1989, as
amended from time to time. 
 “GAAP” - means generally accepted accounting
principles in the United States set forth in the statements and interpretations, as codified, of the Financial Accounting Standards Board or such other principles as may be approved by a significant segment of the accounting profession in the United
States, that are applicable to the circumstances as of the date of determination, subject, however, to the matters addressed in Section 6.7. 

“General Contractor” – means, collectively, the Bluegrass Valley II General Contractor and the Lehigh Valley II General
Contractor. 
 “General Uses” – shall mean the following purposes for which the Loan proceeds may be used from and
after the occurrence of the Spin-Off: financing the construction of the Construction Improvements, payment of any finishing costs with respect to the Properties (including, without limitation, amounts due under any Close-Out Agreements), general
working capital, debt service, operating and carrying costs for the Properties, payment of Leasing Commissions for Approved Leases, construction of the Tenant Improvements and payment of fees due under the Management Agreements, the Development
Agreements, or the Advisory Agreement. 
 “Gross Operating Income” – means the sum of any and all amounts, payments,
fees, rentals, additional rentals, expense reimbursements (including, without limitation, all reimbursements by tenants, lessees, licensees and other users of the Properties), income, interest and other monies directly or indirectly received by or
on behalf of or credited to Borrowers from any person with respect to Borrowers’ ownership, use, development, operation, leasing, franchising, marketing or licensing of the Properties, including, without limitation, from parking operations.
Gross Operating Income shall be computed on a cash basis and shall include for each quarterly statement all amounts actually received in such quarter whether or not such amounts are attributable to a charge arising in such quarter. 

“Governmental Authority” – means any nation or government, any federal, state, local, municipal or other political
subdivision thereof or any entity exercising executive, legislative, judicial, regulatory or administrative functions of or pertaining to government. 

“Guarantor” – means Holdco, a replacement guarantor as may be requested by Borrowers, subject to the approval of Lender
in Lender’s sole and absolute discretion, and any other Person who, or 

  

					
		 	6	  	Loan No. 1015003

 
which, in any manner, is or becomes obligated to Lender under any guaranty now or hereafter executed in connection with respect to the Loan (collectively or severally as the context thereof may
suggest or require). 
 “Guarantor Account Funds” – means all sums now or hereafter on deposit in or payable or
withdrawable from any of the Master Operating Account or the Guarantor Reserve Account. 
 “Guarantor Cash Management
Agreement” – means the Cash Management Agreement between Guarantor and Lender, dated as of the date hereof (as the same may be amended, restated, supplemented or modified from time to time). 

“Guarantor Reserve Account” – shall have the meaning given to such term in the Guarantor Cash Management Agreement. 

“Guaranty” – shall have the meaning given such term in Exhibit B hereto. 

“Hazardous Materials Indemnity Agreement” or “Indemnity – means that certain Hazardous Materials Indemnity
Agreement (Unsecured) of even date herewith executed by and among Borrowers and Guarantor, each as Indemnitor, and Lender. 

“Holdco” - means DC Liquidating Assets Holdco LLC, a Delaware limited liability
company. 
 “IPT” - means Industrial Property Trust Inc., a Maryland corporation.

 “In-Balance” – means, with respect to the Loan and each Construction Property, Lender’s determination from time
to time that any undisbursed Loan funds together with all sums, if any, to be provided by Borrowers as shown in the Loan Budget for such Construction Property, shall be at all times equal to or greater than the amount which Lender from time to time
reasonably determines necessary to: (i) pay, through Completion, all costs of development, construction, marketing and leasing of such Construction Property in accordance with the Loan Documents; (ii) pay all sums scheduled to accrue under
the Loan Documents prior to repayment of the Loan; and (iii) perform and satisfy all of the covenants of Borrowers contained in the Loan Documents prior to repayment of the Loan. 

“In-Balance Payments” – means all payments required from time to time under Section 4.15 hereof. 

“Indemnitees” – means Lender, Lender’s parents, subsidiaries and affiliates, any holder of or participant in the
Loan and all directors, officers, agents, successors and assigns of any of the foregoing. 
 “Indemnitor” - means the Borrowers and the Guarantor, and any other Person who, or which, in any manner, is or becomes obligated to Lender under any indemnity now or hereafter executed in connection with respect to the Loan
(collectively or severally as the context thereof may suggest or require). 
 “Initial Disbursement” – means a
disbursement of the proceeds in an amount equal to the aggregate amount of the Closing Date Uses. 
 “L/C Cash Collateral
Account” – means the account held at Bank of America, N.A. into which the L/C Cash Collateral Amount will be deposited until the expiration of all Bank of America Letters of Credit. 

“L/C Cash Collateral Amount” – means a maximum amount equal to ONE MILLION SIX HUNDRED FIFTY SIX THOUSAND FIVE HUNDRED
THIRTY AND NO/100 DOLLARS ($1,656,530). 

  

					
		 	7	  	Loan No. 1015003

 “Leases” - means all lease agreements of
any Property, or any portion thereof, and all other agreements of any kind relating to the use or occupancy of any Property, or any portion thereof, and every renewal, modification or amendment thereof, whether now existing or entered into after the
date hereof. 
 “Leasing Commissions” - means any and all commissions payable to
independent third party real estate brokers who were involved in the execution of each Approved Lease after the Effective Date. 

“Lehigh Valley II Architect” – means Ware Malcolm, the architect retained by the Lehigh Valley II Borrower with respect
to the Construction Improvements relating to the Lehigh Valley II Property. 
 “Lehigh Valley II Borrower” – the
Borrower that owns the Lehigh Valley II Property. 
 “Lehigh Valley II General Contractor” – means R.S.
Mowery & Sons, Inc., the general contractor retained by the Lehigh Valley II Borrower with respect to the Construction Improvements relating to the Lehigh Valley II Property. 

“Lehigh Valley I Property” – means the Property more particularly described on Exhibit A-8 attached hereto as
being the “Lehigh Valley I Property.” 
 “Lehigh Valley II Property” – means the Property more particularly
described on Exhibit A-9 attached hereto as being the “Lehigh Valley II Property.” 
 “Lender” - has the meaning ascribed to such term in the preamble hereto. 
 “Listing Agent” - means the Person engaged by each applicable Borrower, and who shall be acceptable to Lender (subject to the last sentence of Section 9.11 herein), for the leasing of each Property. 

“Listing Agreement” – means each listing agreement by and between each applicable Borrower and a Listing Agent, the form
and substance of which shall be acceptable to Lender (subject to the last sentence of Section 9.11 herein). 
 “Listing
Agreement Subordination” – means a document or documents, in form and substance satisfactory to Lender, pursuant to which Listing Agent acknowledges and agrees to the collateral assignment of the applicable Listing Agreement to Lender
and subordinates the Listing Agreement to the applicable Security Instrument on terms and conditions reasonably satisfactory to Lender. 

“Loan” - means the principal sum that Lender agrees to lend and Borrowers agree to
borrow pursuant to the terms and conditions of this Agreement, being ONE HUNDRED TWENTY MILLION AND NO/100 DOLLARS ($120,000,000.00). 

“Loan Budget” – means the Loan Budget attached hereto as Exhibit C, as the same may be amended, modified,
supplemented or replaced from time to time. 
 “Loan Documents” - means those
documents, as hereafter amended, supplemented, replaced or modified from time to time, properly executed and in recordable form, if necessary, listed in Exhibit B as Loan Documents. 

“Loan-to-Value Percentage” - has the meaning ascribed to such term in Section 2.13(f). 
 “Lockbox
Account” – shall have the meaning given to such term in the Borrowers Cash Management Agreement. 

  

					
		 	8	  	Loan No. 1015003

 “Major Subcontractor” – means any subcontractor or materialman having a
contract value for any portion of the Construction Improvements in an amount of $500,000 or more. 
 “Management Agreement” - means each management agreement by and between each applicable Borrower and a Manager, the form and substance of which shall be acceptable to Lender. 

“Management Agreement Subordination” – means a document or documents, in form and substance satisfactory to Lender,
pursuant to which Manager acknowledges and agrees to the collateral assignment of a Management Agreement to Lender and subordinates the Management Agreement to the applicable Security Instrument on terms and conditions reasonably satisfactory to
Lender. 
 “Manager” - means the Person or Persons engaged by each applicable
Borrower, and who shall be acceptable to Lender, for the management, leasing and operation of each Property. 
 “Master Operating
Account” – shall have the meaning given to such term in the Guarantor Cash Management Agreement. 
 “Material
Contract” – means any contract (other than a Construction Contract, Development Agreement, Management Agreement, Advisory Agreement, and Leases) entered into by or on behalf of any Borrower relating to the leasing, ownership,
management, use, operation, maintenance or repair of any Property with a duration of more than twelve (12) months (unless terminable on thirty (30) or fewer days notice) or with annual payments in excess of One Hundred Thousand Dollars
($100,000). 
 “Material Adverse Effect” - means a material adverse effect upon
(i) the business or financial position or results of operation of the Borrowers taken as a whole, (ii) the ability of the Borrowers to perform, or of Lender to enforce, the Loan Documents taken as a whole, (iii) the Properties taken
as a whole or the aggregate values thereof, or (iv) the ability of the Guarantor to perform under the guaranties taken as a whole given in connection with the Loan; provided, however, that for purposes of Section 2.13(i) only, the
foregoing (i) through (iv) shall be determined on the basis of the results and status of each Borrower, Property and/or guaranty (as applicable) individually and not on an aggregate basis. 

“Maturity Date” - means the Original Maturity Date or the Extended Maturity Date, as
applicable. 
 “Miami III Borrower” – the Borrower that owns the Miami III Property. 

“Miami III Property” – means the Property more particularly described on Exhibit A-3 attached hereto as being the
“Miami III Property.” 
 “Net Effective Rent” - means, as for any Lease on
a square foot basis, the annualized base rent payable under such Lease, as reduced for any amounts paid by Borrower directly to or on behalf of the tenant for the purpose of inducing the tenant to enter into such Lease, including, without
limitation, an excessive tenant improvement allowance (for purposes of tenant improvements, any amount in excess of 110% of the budgeted tenant improvements allowance in the most recent Appraisal delivered to Lender shall be deemed excessive),
moving expenses, free rent periods or abatements or lease buyouts, as amortized over the life of the Lease. 
 “Net Sales
Proceeds” – means, in the case of a Transfer of a Property, the gross sales price of such Property net of the amount of any disposition fees payable under the Advisory Agreement, good faith estimated tax distributions to the beneficial
owners of the Holdco or Trust, out-of-pocket legal fees, title and recording tax expenses, commissions and other customary fees and expenses actually incurred by or on behalf of a Person in connection therewith and paid or payable to any Person
other than an Affiliate of any Borrower (except in the case of disposition 

  

					
		 	9	  	Loan No. 1015003

 
fees under the Advisory Agreement and good faith estimated tax distributions); provided, that the aggregate amount of such fees, expenses, and distributions shall not exceed 6% of the
gross sales price of such Property. 
 “NFA” - has the meaning ascribed to such term
in Section 2.13(k). 
 “Note” - means that certain Promissory Note of
even date herewith, in the original principal amount of the Loan, executed by each Borrower and payable to the order of Lender, as hereafter amended, supplemented, replaced or modified. 

“Obligor” means any Borrower or Guarantor. 

“OFAC” – means the United States Treasury Department Office of Foreign Assets Control and any successor thereto. 

“Operating Account” – shall have the meaning given to such term in the Borrowers Cash Management Agreement. 

“Option to Extend” - means Borrowers’ option, subject to the terms and conditions
of Section 2.13, to extend the term of the Loan from the Original Maturity Date to the Extended Maturity Date. 

“Original Maturity Date” - means November 3, 2017. 

“Other Related Documents” - means those documents, as hereafter amended, supplemented,
replaced or modified from time to time, properly executed and in recordable form, if necessary, listed in Exhibit B as Other Related Documents. 

“Outstanding Amount Debt Yield” - means as of the applicable Determination Date, the Projected Net Operating Income of the
Properties for the applicable six (6) month period commencing from the date immediately succeeding such applicable Determination Date, which amount shall be annualized by multiplying by two (2), divided by the Estimated Loan Amount Outstanding,
with such fraction expressed as a percentage. 
 “Permitted Debt” means (a) unsecured non-interest bearing ordinary
course obligations, including trade payables or other accruals, incurred in connection with Borrowers’ ordinary course of business that: (i) do not exceed two percent (2%) of the outstanding balance of the Loan; (ii) are not
evidenced by a note; (iii) must be paid within sixty (60) days; and (iv) are otherwise expressly permitted under the Loan Documents, (b) the Bank of America Letters of Credit, and (c) deferred payment of fees due under the
Management Agreements, the Development Agreements, or the Advisory Agreement. 
 “Permitted Transfer” – means a
Transfer permitted under Section 9.18(b) or Section 9.19(b). 
 “Person” – means any
individual, sole proprietorship, corporation, general partnership, limited partnership, limited liability company, joint venture, association, joint-stock company, bank, trust, land trust, estate, association, joint stock company, unincorporated
organization, any federal, state, county or municipal government (or any agency or political subdivision thereof), endowment fund or any other form of entity. With respect to any Sanctioned Person, “Person” shall also include any group,
sector, territory or country. 
 “Plans and Specifications” - means any and all
plans and specifications prepared by each applicable Architect for the construction of the Construction Improvements and by each of the other Design Professionals for the construction of the Tenant Improvements heretofore or hereafter delivered to
and approved by Lender, as amended in order to comply with the terms and conditions of this Agreement. 

  

					
		 	10	  	Loan No. 1015003

 “Prohibited Equity Transfer” - has the
meaning ascribed to such term in Section 9.14(a). 
 “Prohibited Property Transfer” - has the meaning ascribed to such term in Section 9.13(a). 
 “Projected Net Operating
Income” – means the in-place, forward net operating income for the applicable future periods of determination based on executed Approved Leases that are executed as of or prior to such date of determination and are or will be effective
during such future projected period of determination. Net operating income shall be (a) the actual rental payments to be received from Approved Leases in each Property in accordance with GAAP, including any rental loss insurance proceeds, if
applicable, (but modified to exclude the straight line recognition of rents and mark to market adjustments); plus (b) the estimated expense reimbursements to be received; plus (c) any and all other normal and recurring income
from each Property to be received; minus (d) projected operating expenses (no less than the then current appraisal estimates, subject to reasonable adjustment by Lender to conform to Lender’s standard practices) of each Property
determined in accordance with GAAP (excluding any interest or principal payments on the Loan, any allowance for depreciation, any similar non-cash accrual expenses, leasing costs and expenses, and any actual capital expenditures or tenant
improvement costs or allowances) payable in the ordinary course of business; provided, however, that such operating expenses shall include (i) property management fees equal to the greater of (A) the property management fees
used in the financial proforma in the then most recent Appraisal approved by Lender, (B) the actual amount of property management fees, and (C) the amount equal to three percent (3%) (prorated on an annual basis) of the amounts set
forth in clauses (a), (b) and (c) above for such applicable period; (ii) annual project reserves equal to the greater of (A) the reserves used in the financial proforma in the then most recent Appraisal
obtained and approved by Lender, and (B) the sum of $0.05 per rentable square feet per year in the Properties and (iii) normalized customary expenses that are typically paid once or twice per calendar year, including, without limitation
real property taxes and insurance premiums. For the avoidance of doubt, revenue set forth above in clauses (a), (b) and (c) shall exclude any concessions provided to a tenant under an Approved Lease for the purpose of
inducing such tenant to enter into such Approved Lease (including, without limitation, an excessive tenant improvement allowance, moving expenses, free rent periods or abatements or lease buyouts). For purposes of determining Projected Net Operating
Income, the following shall not be, or shall cease to be, an Approved Lease: (1) a Lease where the tenant is or becomes insolvent or seeks bankruptcy protection; (2) a Lease where a material default has occurred and is continuing; or
(3) a Lease that has been terminated prior to or is scheduled to be terminated or expires during the applicable six (6) month period immediately following an applicable Determination Date for calculating such Projected Net Operating
Income. 
 “Property” or “Properties” - has the meaning ascribed to
such term in the Recitals. 
 “Property Level Budget” - means each of the Property specific loan budgets attached hereto as
Exhibit I, as the same may be amended, modified, supplemented or replaced from time to time. 
 “Recourse
Guaranty” – shall have the meaning given such term in Exhibit B hereto. 
 “Redlands Property”
– means the Property more particularly described on Exhibit A-1 attached hereto as being the “Redlands Property.” 

“Restricted Party” - shall mean each of (i) Borrower, (ii) Guarantor and (iii) any Constituent Entity of
Borrower owning twenty percent (20%) or more of the ownership interests of Borrower. 

  

					
		 	11	  	Loan No. 1015003

 “Sanction” or “Sanctions” - means individually and
collectively, respectively, any and all economic or financial sanctions, sectoral sanctions, secondary sanctions, trade embargoes and anti-terrorism laws, including but not limited to those imposed, administered or enforced from time to time by:
(a) the United States of America, including those administered by the OFAC, the U.S. State Department, the U.S. Department of Commerce, or through any existing or future Executive Order, (b) the United Nations Security Council,
(c) the European Union, (d) the United Kingdom, or (e) any other governmental authorities with jurisdiction over any Person within the Borrowing Group. 

“Sanctioned Person” - means any Person that is a target of Sanctions, including without limitation, a Person that is:
(a) listed on OFAC’s Specially Designated Nationals and Blocked Persons List; (b) listed on OFAC’s Consolidated Non-Specially Designated Nationals List; (c) a legal entity that is deemed by OFAC to be a Sanctions target
based on the ownership of such legal entity by Sanctioned Peron(s); or (d) a Person that is a Sanctions target pursuant to any territorial or country-based Sanctions program. 

“Security Deposit Account” - has the meaning ascribed to such term in
Section 9.8. 
 “Security Instruments” – mean each mortgage, deed to secure debt, deed of trust or other
security instrument executed by a Borrower in favor, and for the benefit, of Lender, relating to each Property, as the same may be amended, modified, supplemented or replaced from time to time. 

“Separateness Provisions” - has the meaning ascribed to such term in Section 7.1(c). 

“Special Distribution” – means a special distribution of a portion of the Loan proceeds by Borrowers to Holdco and its
direct and indirect owners, including, without limitation, the beneficial owners of the Trust. 
 “Spin-Off” – means
the spin-off of Holdco from IIT Real Estate Holdco LLC, a Delaware limited liability company substantially concurrently with the Effective Date, resulting in (a) one hundred percent (100%) of the common membership interests in Holdco being
owned by the Trust, (b) one hundred percent (100%) of the special membership interests being owned by DCG Retained Properties Special Member LLC, a Delaware limited liability company and (c) the direct or indirect interests in the
Properties being contributed to Holdco. 
 “Subdivision Map” - shall have the
meaning ascribed to such term in Section 9.6. 
 “Swap Agreement” – means a “swap agreement” as
defined in Section 101 of the Bankruptcy Code, entered into by Borrowers and Lender (or with another financial institution which is reasonably acceptable to Lender), together with all modifications, extensions, renewals and replacements
thereof. 
 “Tenant Improvements” - means each Lender approved tenant improvements
requested by a Borrower with respect to such Borrower’s obligations therefor under an Approved Lease; provided however, that no tenant improvements in connection with a Deemed Approved Lease shall require Lender approval. 

“TI/LC Expenses” - has the meaning ascribed to such term in Section 3.7.

 “Title Company” - means (i) with respect to the Lehigh Valley I Property and
the Lehigh Valley II Property, First American Title Insurance Company and (ii) with respect to all other Properties, Stewart Title Guaranty Company. 

“Title Policy” - means the standard ALTA promulgated form of Loan Policy of Title
Insurance as issued by the applicable Title Company. 

  

					
		 	12	  	Loan No. 1015003

 “Transfer” - means any sale, installment
sale, exchange, mortgage, pledge, hypothecation, assignment, encumbrance or other transfer, conveyance or disposition, whether voluntarily, involuntarily or by operation of law or otherwise (excluding Leases permitted under this Agreement). 

“Trust” - means DC Industrial Liquidating Trust, a Maryland statutory trust. 

“UCC” - means the Uniform Commercial Code in effect from time to time in the state where a Borrower is organized and where a
Property is located, as applicable, as now or hereafter amended or modified. 
 “Unpaid Advisory Fees” - has the meaning ascribed to such term in Section 9.6. 
 ARTICLE 2. LOAN 

 

	2.1	LOAN. Subject to the terms of this Agreement, Lender agrees to lend to Borrowers and Borrowers agree to borrow from Lender the principal sum of up to One Hundred Twenty Million and No/100ths Dollars
($120,000,000.00) (the “Commitment Amount”); said sum to be evidenced by the Note. This Loan is not a revolving credit line, and no payments or credits shall increase the maximum amount of advances available from the Loan. The Loan
shall bear interest and be repaid in accordance with the provisions of the Note. 

  

	2.2	PURPOSE. Amounts disbursed to or on behalf of Borrower pursuant to the Note shall be used (i) in connection with the closing of the Loan, the Closing Date Uses and (ii) from and after the
occurrence of the Spin-Off, the General Uses, and for such other purposes and uses as may be permitted under this Agreement and the other Loan Documents. 

  

	2.3	GRANT OF SECURITY INTEREST IN REAL PROPERTY. The Note shall be secured, in part, by the Security Instruments encumbering certain real property and improvements as described therein. 

 

	2.4	GRANT OF SECURITY INTEREST IN ACCOUNTS; APPLICATION OF FUNDS. As security for payment of the Loan and the performance by Borrowers of all other terms, conditions and provisions of the Loan Documents, each
Borrower, as debtor, hereby pledges and assigns to Lender, and grants to Lender a security interest in, all of such Borrower’s right, title and interest in and to all Accounts. No Borrower shall, without obtaining the prior written consent of
Lender, further pledge, assign or grant any security interest in any of the Accounts, or permit any lien to attach thereto, or any levy to be made thereon, or any UCC Financing Statements to be filed thereon, except those naming Lender as the
secured party, to be filed with respect thereto. This Agreement is, among other things, intended by the parties to be a security agreement for purposes of the UCC. Upon the occurrence and during the continuance of a Default, Lender may apply all or
any part of the Account Funds against the amounts outstanding under the Loan in any order and in any manner as Lender shall elect in Lender’s sole discretion without seeking the appointment of a receiver and without adversely affecting the
rights of Lender to foreclose the liens and security interests securing the Loan or exercise its other rights under the Loan Documents. The Account Funds shall not constitute trust funds and may be commingled with other monies held by Lender. All
interest, if any, which accrues on the Account Funds and Guarantor Account Funds shall be at a rate established by Lender, which may or may not be the highest rate then available, shall accrue for the benefit of Borrowers or Guarantor, as
applicable, and shall be taxable to Borrowers and shall be added to and disbursed in the same manner and under the same conditions as the principal sum on which said interest accrued. Upon repayment in full of Borrowers’ obligations under the
Loan Documents, all remaining Account Funds, if any, shall be disbursed to Borrowers within ten (10) Business Days. 

  

					
		 	13	  	Loan No. 1015003

	2.5	ADDITIONAL SECURITY INTEREST. Each Borrower hereby grants and assigns to Lender a security interest, to secure payment and performance of all obligations, in all of such Borrower’s right, title and
interest, now or hereafter acquired, to the payment of money from Lender to such Borrower under any Swap Agreement. 

  

	2.6	LOAN FEE. Borrowers shall pay to Lender a loan fee as set forth in, and in accordance with, the Fee Letter. 

  

	2.7	LOAN DOCUMENTS. Borrowers shall deliver to Lender concurrently with this Agreement each of the documents, each properly executed and in recordable form, as applicable, described in Exhibit B as
Loan Documents, together with those documents described in Exhibit B as Other Related Documents. 

  

	2.8	EFFECTIVE DATE. The effective date of the Loan Documents shall be the Effective Date. 

  

	2.9	MATURITY DATE. All sums due and owing under this Agreement and the other Loan Documents shall be repaid in full on the Maturity Date. All payments due to Lender under this Agreement, whether at the
Maturity Date or otherwise, shall be paid in Dollars, in immediately available funds. 

  

	2.10	PREPAYMENT. The Loan is prepayable in full or in part at any time, without a prepayment penalty; provided however, that any partial or full repayment of the Loan will be subject to payment of
termination fees on any outstanding Swap Agreement or LIBOR contract. If the outstanding principal balance of the Loan ever exceeds the maximum amount of the Loan, then all such amounts shall nonetheless be evidenced by the Note, guaranteed by any
applicable guaranty granted in connection with the Loan and secured by the Security Instrument; provided, however, Borrowers shall, within five (5) Business Days after Lender’s demand or any Borrower’s earlier discovery
of such advance, pay to Lender an amount equal to such excess principal amount and accrued but unpaid interest thereon. 

  

	2.11	FULL REPAYMENT AND RECONVEYANCE, SATISFACTION OR RELEASE. Upon receipt of all sums owing and outstanding under the Loan Documents, and the full performance of all other obligations secured by the Security
Instrument, Lender shall reconvey, satisfy or release the Properties from the lien of the Security Instruments and terminate any assignment of leases and rents and UCC Financing Statements related to the Collateral; provided, however,
that all of the following conditions shall be satisfied at the time of, and with respect to, such reconveyance, satisfaction or release: (a) Lender shall have received all escrow, closing and recording costs, the costs of preparing and
delivering such reconveyance, satisfaction or release, the payment of any and all sums then due and payable under the Loan Documents, and the full payment and performance of all other obligations secured by the Security Instrument, including,
without limitation, those set forth in the Note and the Security Instrument; and (b) Lender shall have received a written release satisfactory to Lender of any set aside letter, letter of credit or other form of undertaking which Lender has
issued to any surety, governmental agency or any other party in connection with the Loan and/or the Properties. Lender’s obligation to make further disbursements under the Loan shall terminate as to any portion of the Loan undisbursed as of the
date of issuance of such reconveyance, satisfaction or release, and any commitment of Lender to lend any undisbursed portion of the Loan shall be cancelled. Any repayment shall be without prejudice to Borrowers’ obligations under any Swap
Agreement between any Borrower and Lender, which shall remain in full force and effect subject to the terms of such Swap Agreement (including provisions that may require a reduction, modification or early termination of a swap transaction, in whole
or in part, in the event of such repayment, and may require Borrowers to pay any fees or other amounts for such reduction, modification or early termination), and no such fees or amounts shall be deemed a penalty hereunder or otherwise.

  

	2.12	PARTIAL RELEASES. At any time prior to the Maturity Date, upon Borrowers’ request, Lender shall issue a partial release (the “Partial Release”) from the lien of a Security Instrument
with respect to any Property; provided, however, that prior to or simultaneously with any such partial release all of the following conditions shall be satisfied: 

 

	 	(a)	Borrower shall have provided Lender with not less than twenty (20) days prior written notice (for the avoidance of doubt, any such notice is revocable by written notice to Lender from the Borrowers given at any
time prior to a Partial Release provided Borrower reimburses Lender for its reasonable costs and expenses (if any) actually incurred in connection with the consummation of such partial release (e.g. costs or preparing release documents)) of the
consummation of a refinancing, sale or transfer with respect to such Property; 

  

					
		 	14	  	Loan No. 1015003

	 	(b)	No Default shall exist (unless such Default shall be cured by the Partial Release requested); 

  

	 	(c)	Borrower shall have executed, or caused the execution of, all such documents and instruments as reasonably requested by Lender in connection with the Partial Release; 

 

	 	(d)	Lender shall have received any and all sums then due and payable under the Loan Documents, and the full payment and performance of all other obligations then due and secured by the applicable Security Instrument,
including, without limitation, those set forth in the Note and such Security Instrument, together with all escrow, closing and recording costs, the costs of preparing and delivering such partial reconveyance, satisfaction or release and the cost of
any title insurance endorsements required by Lender, including, without limitation, a partial reconveyance or release endorsement; 

  

	 	(e)	For each Property to be released, Lender shall have received a release price (the “Release Price”) for such Property either (a) the greater of an amount equal to (1) one hundred percent
(100%) of the Net Sales Proceeds received by Borrower upon any sale or transfer of such Property, and (2) one hundred sixty-five percent (165%) of the Allocated Loan Amount for such Property, or (b) such other amount agreed to in
writing by Lender prior such release; 

  

	 	(f)	Any Release Price shall be applied to the principal of the Loan and may not be reborrowed. If, after such application, any portion of the Release Price exceeds the outstanding principal balance of the Loan and Borrower
has not otherwise satisfied the outstanding obligations under the Loan Documents and terminated all undisbursed commitments, such excess shall be deposited into the Guarantor Reserve Account; and 

 

	 	(g)	Following Lender’s receipt of a certification from Borrowers affirming that the conditions set forth in this Section have been satisfied (including, without limitation, attached calculations demonstrating
compliance with subsection (e)) and the release of a Property in accordance with this Section, Lender will release the Borrower who owns or owned such released Property from its obligations under this Agreement, the Loan Documents and the
Other Related Documents. Notwithstanding the release of any Borrower pursuant to this Section 2.12(g), such Borrower shall continue to be liable for all obligations which expressly survive the release, satisfaction or cancellation of the
Note or any obligations under the Loan Documents. 

 Neither the acceptance of any payment nor the issuance of any Partial
Release by Lender shall affect Borrowers’ (other than any Borrower released in accordance with this Section 2.12) obligation to repay all amounts owing under the Loan Documents or under the lien of any Security Instrument on the
remainder of the Properties which are not reconveyed, satisfied or released. Any partial prepayment shall be without prejudice to Borrower’s obligations under any Swap Agreement between Borrowers and Lender which shall remain in full force and
effect subject to the terms of such Swap Agreement (including provisions that may require a reduction, modification or early termination of a swap transaction, in whole or in part, in the event of such

  

					
		 	15	  	Loan No. 1015003

 
prepayment, and may require Borrowers to pay any fees or other amounts for such reduction, modification or early termination), and no such fees or amounts shall be deemed a penalty hereunder or
otherwise; 
  

	2.13	OPTION TO EXTEND. Borrowers shall have the option to extend the term of the Loan from the Original Maturity Date, to the Extended Maturity Date, upon satisfaction (or waiver by Lender in writing) of each
and every one of the following conditions precedent: 

  

	 	(a)	Borrowers shall provide Lender with written notice of Borrowers’ request to exercise the Option to Extend in the form attached hereto as Exhibit H not more than one hundred twenty (120) days but not
less than forty-five (45) days prior to the Original Maturity Date. 

  

	 	(b)	As of the date of Borrowers’ delivery of notice of request to exercise the Option to Extend, and as of the Original Maturity Date, no Default shall have occurred and be continuing, and Borrowers shall so certify in
writing. 

  

	 	(c)	Section 4.2 hereunder shall be satisfied as of the Original Maturity Date. 

  

	 	(d)	Borrowers shall execute or cause the execution of all documents reasonably required by Lender to exercise the Option to Extend (including, without limitation, a certification by Borrowers that all conditions precedent
for the extension have been satisfied) and shall deliver to Lender, at Borrowers’ sole cost and expense, such title insurance endorsements required under Section 2.13(g) below. 

 

	 	(e)	Borrowers shall pay to Lender an extension fee in the amount of twenty-five one-hundredths of one percent (0.25%) of the Commitment Amount, less any unfunded amounts being cancelled and/or principal payments previously
made or concurrently made in order to satisfy the Loan-to-Value Percentage requirement and the Outstanding Amount Debt Yield minimum requirement, pursuant to Section 2.13(h), for the extension, payable in full concurrently with the
execution of all documents contemplated in Section 2.13(d) above. 

  

	 	(f)	If required by Lender, at least twenty (20) days prior to the Original Maturity Date, Lender shall have received, at Borrowers’ sole expense, an Appraisal (subject to review and reasonable adjustment by Lender
to conform to Lender’s standard practices), confirming to the satisfaction of Lender that (i) (x) the then outstanding principal balance of the Note plus (y) the amount of any unfunded TI/LC Expenses to be funded from the Loan
proceeds in connection with Leases taken into account when determining the “as-is” market value In the Appraisal as a percentage of (ii) the applicable appraised value of the Properties and Improvements
then subject to Security Instruments, in the aggregate, does not exceed fifty percent (50%) of the “as-is” market value (“Loan-to-Value
Percentage”) as of the Original Maturity Date; provided, however, in the event such as-is market value is not adequate to meet the required
Loan-to-Value Percentage, then Borrower shall pay down the outstanding principal balance of the Loan such that said required Loan-to-Value Percentage shall be met on or before the the Original Maturity Date. The valuation date of each Appraisal shall be within sixty (60) days of each applicable reference date specified
above. Any principal balance reduction shall reduce the Commitment Amount by a like amount and may not be reborrowed. 

  

	 	(g)	Lender shall have received a date-down endorsement and other endorsements amending the mechanic’s and materialmen’s lien coverage and, if applicable, deleting the pending disbursements clause and such other
endorsements reasonably required by Lender, in form and content satisfactory to Lender. 

  

					
		 	16	  	Loan No. 1015003

	 	(h)	As of the Determination Date immediately prior to the Original Maturity Date, Lender shall have received and approved projected financial statements and supporting documents demonstrating that the Outstanding Amount
Debt Yield for the Properties then subject to Security Instruments equals or exceeds ten percent (10%). If the Outstanding Amount Debt Yield as so calculated for such Properties does not equal or exceed such minimum percent threshold, then Borrowers
shall pay down the outstanding principal balance of the Loan such that the recalculated Outstanding Amount Debt Yield shall equal or exceed ten percent (10%) on or before the Original Maturity Date. Any principal balance reduction shall reduce
the Commitment Amount by a like amount and may not be reborrowed. 

  

	 	(i)	Borrowers shall have commenced construction of the Construction Improvements on the Lehigh Valley II Property or the Lehigh Valley II Property shall have been subject to a Partial Release and no longer subject to a
Security Instrument. 

  

	 	(j)	There shall have occurred no Material Adverse Effect in the financial condition of any Borrower or Guarantor from that which existed as of the later of: (A) the Effective Date or (B) the date upon which the
financial condition of such party was first represented to Lender. 

  

	 	(k)	If the Miami III Property has not otherwise been released in accordance with Section 2.12 prior to the Original Maturity Date, Borrowers shall have either (i) (x) delivered to Lender evidence of
the satisfaction of all requirements set forth in the letter dated January 30, 2015 from Miami-Dade County Department of Regulatory and Economic Resources (“DERM”) to the Miami III Borrower, and (y) obtained a no
further action letter (or such reasonably similar letter actually provided by DERM (as hereinafter defined), the “NFA”) with respect to the Miami III Property, or (ii) obtained the release of the Miami III Property by
delivering to Lender a release price for the Miami III Property equal to one hundred sixty-five percent (165%) of the Allocated Loan Amount for the Miami III Property (for avoidance of doubt, the Miami III Property may be released in accordance
with Section 2.12 at any time prior to the Original Maturity Date, and the foregoing clause (ii) shall only apply if the Miami III Property has not otherwise been released prior to the Original Maturity Date in accordance with
Section 2.12). 

 Except as modified by this Option to Extend, the terms and conditions of this Agreement and the
other Loan Documents as modified and approved by Lender shall remain unmodified and in full force and effect. 
  

	2.14	RECOURSE. The Loan shall be full recourse to each Borrower and all of its assets, whether now owned or hereafter acquired or in which any Borrower otherwise has an interest, and all proceeds thereof.

 ARTICLE 3. DISBURSEMENT 
  

	3.1	CONDITIONS PRECEDENT. 

  

	 	(a)	Lender’s obligation to close the Loan transaction contemplated by this Agreement shall be subject to Borrowers’ compliance with and/or satisfaction (as the context so requires) of (or waiver by the Lender
thereof in writing), each of the following conditions precedent, in each case, to the satisfaction of Lender in its reasonable discretion: 

  

	 	(i)	Receipt and approval by Lender of an executed original of this Agreement, each of the Loan Documents, the Other Related Documents and any and all other documents, instruments, policies and forms of evidence or other
materials which are required pursuant to this Agreement, each in form and content acceptable to Lender; 

  

					
		 	17	  	Loan No. 1015003

	 	(ii)	There shall exist no Default, as defined in this Agreement, or Default as defined in any of the other Loan Documents or in the Other Related Documents; 

 

	 	(iii)	Each Security Instrument shall constitute a valid lien upon the respective Property covered by such Security Instrument, and shall be prior and superior to all other liens and encumbrances thereon except those approved
by Lender in writing (including, without limitation, all exceptions under any Lender’s Title Policy approved by Lender in connection with closing); 

  

	 	(iv)	Lender has received and approved in form and substance satisfactory to Lender: 

  

	 	1.	UCC, judgment lien and federal tax lien searches with respect to each Borrower and Guarantor, in the state/county in which each such party is organized; 

 

	 	2.	all authorizations and permits which are then procurable and required by any Applicable Laws in connection with the zoning and use of each Property; 

 

	 	3.	a current survey of each Property meeting American Land Title Association (“ALTA”) standards, certified to Lender, and the Title Company, showing the boundaries of such Property by courses and
distances, together with a corresponding metes and bounds description, the actual or proposed location of all improvements, encroachments and restrictions, the location and width of all easements, utility lines, rights-of-way and building set-back
lines, and notes referencing book and page numbers for the instruments granting the same; 

  

	 	4.	Borrowers shall have fulfilled the insurance requirements under Article 5 of this Agreement and Lender and its consultants shall have approved the same; 

 

	 	5.	Title Policies, together with any endorsements which Lender may require, insuring the principal amount of the Loan and the validity and the priority of the lien of the Security Instruments upon each Property, subject
only to matters approved by Lender in writing; 

  

	 	6.	evidence satisfactory to Lender that no Property is located within the 100-year flood plain or identified as a special flood hazard area as defined by the Federal Insurance Administration, or if any portion of a
Property is so located within the 100-year flood plain or identified as a special flood hazard area, evidence that flood insurance is in effect; 

  

	 	7.	opinions of counsel for Borrowers and Guarantor satisfactory to Lender, dated as of the date of the first advance hereunder and relating to such matters with respect to this Agreement and the transaction contemplated
hereby as Lender may request; 

  

	 	8.	 with respect to each Borrower and Guarantor: (A) copies certified as true and complete of the following documents from the applicable
Governmental Authority: (1) the articles or certificate of incorporation, certificate of formation, certificates of trust, or certificate of limited 

  

					
		 	18	  	Loan No. 1015003

	 	
partnership, as applicable; and (2) good standing certificates or certificates of existence from the jurisdictions in which each Borrower and Guarantor is organized and/or qualified to do
business dated not more than thirty (30) days prior to the date of this Agreement and (B) true and complete copies of the by-laws, partnership agreement, trust agreement or operating agreement, as applicable, of each Borrower and
Guarantor, certified as of the date of this Agreement as complete and correct copies thereof by the Secretary or an Assistant Secretary, general partner, manager or other authorized representative reasonably acceptable to Lender, of each Borrower
and Guarantor; 

  

	 	9.	resolutions, in form and substance satisfactory to Lender, of each Borrower, Guarantor and such other Persons as Lender may request, authorizing the execution, delivery and performance of the Loan Documents and Other
Related Documents to which such Person is a party and the transactions contemplated thereby, certified as of the date of this agreement by the Secretary or an Assistant Secretary, general partner, manager or other authorized representative
reasonably acceptable to Lender, of such Person, which certificates shall state that the resolutions thereby certified have not been amended, modified, revoked or rescinded; 

 

	 	10.	a copy of any existing leases, management agreement, development agreement, maintenance agreement or brokerage agreement; 

  

	 	11.	the most recent certified rent roll delivered to Lender by Borrowers in accordance with the requirements of Section 10.5 hereof; 

 

	 	12.	an Appraisal prepared by an appraiser acceptable to Lender and approved by Lender showing the value of each Property, all in form, substance and amount acceptable to Lender; 

 

	 	13.	a current Phase I environmental report (and additional reports if required by Lender) of each Property for any toxic or hazardous substances or materials (whether products or waste), asbestos or PCBs performed by a
qualified engineer which inspection report shall be in form and substance acceptable to Lender; and 

  

	 	14.	to the extent commercially reasonable to obtain, executed subordination, non-disturbance and attornment agreements and estoppel certificates from the tenants under Approved Leases, in form and substance satisfactory to
Lender; 

  

	 	(v)	 With respect to the Bluegrass Valley II Property, Lender shall have received and approved in form and substance satisfactory to Lender the following:
(A) if requested by Lender, a soils report; (B) a copy of any Plans and Specifications for the Construction Improvements, certified as complete by the Architect, and, if requested by Lender, a copy of any Plans and Specifications for the
Tenant Improvements, together with evidence of all necessary or appropriate approvals of governmental agencies or private parties; (C) evidence of all necessary or appropriate approvals, building permits and licenses for the construction of the
Construction Improvements from all applicable Governmental Authorities; (D) copies of all agreements which are material to Completion of the Construction Improvements, including the Construction Agreement with the General Contractor, as to
disbursements relating to the construction of the Construction Improvements and, if requested by Lender, all agreements material 

  

					
		 	19	  	Loan No. 1015003

	 	
for the construction of the Tenant Improvements, including the applicable Construction Agreements with other Contractors as to disbursements relating to the construction of the Tenant
Improvements; (E) copies of any initial study, negative declaration, mitigated negative declaration, environmental impact report, notice of determination or notice of exemption prepared, adopted, certified or filed by or with any governmental
agency; (F) a final Loan Budget and (G) a construction costing analysis; 

  

	 	(vi)	The Loan Documents have been duly authorized, executed and, if applicable, in proper form for filing or recordation (and are in the possession of the applicable escrow agent for recording substantially concurrently with
the closing of the Loan) in accordance with requirements of all applicable laws, rules, regulations and orders of a governmental authority, and original counterparts thereof delivered to Lender; 

 

	 	(vii)	Borrowers’ Equity Requirement has been satisfied; 

  

	 	(viii)	The Loan shall be In-Balance; 

  

	 	(ix)	Borrowers have paid to Lender, or any other person or party entitled thereto, all fees and costs then due and payable in connection with this Agreement and the subject hereof; 

 

	 	(x)	Borrowers have established the Accounts; and 

  

	 	(xi)	the representations and warranties contained in this Agreement shall be true and correct in all material respects (or, in the case of any representation or warranty expressly qualified by materiality or Material Adverse
Effect, in all respects) on and as of such date of such borrowing with the same effect as though made on and as of such date, except to the extent such representations and warranties expressly relate to an earlier date, in which case such
representations and warranties shall have been true and correct in all material respects (or, in the case of any representation or warranty expressly qualified by materiality or Material Adverse Effect, in all respects) as of such earlier date; and

  

	 	(xii)	Borrowers shall have deposited $6,000,000 in equity into the Master Operating Account, which sum shall be used to pay for the items described in Column D of the Loan Budget. 

 

	 	(xiii)	Borrowers shall have deposited $7,500,000 in equity into the Guarantor Reserve Account on or before the date hereof. 

  

	 	(xiv)	Borrowers shall have deposited $2,500,000 in equity into the Master Operating Account on or before the date hereof. 

  

	 	(b)	Lender’s obligation to disburse any Loan proceeds subsequent to the Initial Disbursement shall be subject to Borrowers’ compliance with and/or satisfaction (as the context so requires) (or waiver by the Lender
thereof in writing) of, each of the following conditions precedent, in each case, to the satisfaction of Lender in its reasonable discretion: 

  

	 	(i)	Borrowers shall have submitted to Lender an Application for Payment which shall be satisfactory to Lender in all respects; 

  

					
		 	20	  	Loan No. 1015003

	 	(ii)	There shall exist no Default, as defined in this Agreement, or Default as defined in any of the other Loan Documents or in the Other Related Documents; 

 

	 	(iii)	The Loan shall be In-Balance; 

  

	 	(iv)	With respect to any disbursement related to the Lehigh Valley II Property, Lender shall have received and approved in form and substance satisfactory to Lender the following: (A) if requested by Lender, a soils
report; (B) a copy of any Plans and Specifications for the Construction Improvements, certified as complete by the Architect, and, if requested by Lender, a copy of any Plans and Specifications for the Tenant Improvements, together with
evidence of all necessary or appropriate approvals of governmental agencies or private parties; (C) evidence of all necessary or appropriate approvals, building permits and licenses for the construction of the Construction Improvements from all
applicable Governmental Authorities; (D) copies of all agreements which are material to Completion of the Construction Improvements, including the Construction Agreement with the General Contractor, as to disbursements relating to the
construction of the Construction Improvements and, if requested by Lender, all agreements material for the construction of the Tenant Improvements, including the applicable Construction Agreements with other Contractors as to disbursements relating
to the construction of the Tenant Improvements; (E) copies of any initial study, negative declaration, mitigated negative declaration, environmental impact report, notice of determination or notice of exemption prepared, adopted, certified or
filed by or with any governmental agency; (F) a final Loan Budget and (G) a construction costing analysis; and 

  

	 	(v)	the representations and warranties contained in this Agreement shall be true and correct in all material respects (or, in the case of any representation or warranty expressly qualified by materiality or Material Adverse
Effect, in all respects) on and as of such date of such borrowing with the same effect as though made on and as of such date, except to the extent such representations and warranties expressly relate to an earlier date, in which case such
representations and warranties shall have been true and correct in all material respects (or, in the case of any representation or warranty expressly qualified by materiality or Material Adverse Effect, in all respects) as of such earlier date.

  

	3.2	ACCOUNT AND DISBURSEMENT AUTHORIZATION. The proceeds of the Loan and Borrowers’ Funds, when qualified for disbursement (subject to the portion of the Initial Disbursement that shall be funded into the
Guarantor Reserve Account), shall be deposited into the Master Operating Account or otherwise disbursed to or for the benefit or account of Borrowers under the terms of this Agreement, the Borrowers Cash Management Agreement and the Guarantor Cash
Management Agreement; provided, however, that any direct disbursements from the Loan which are made by means of wire transfer, shall be subject to the provisions of Section 3.3. Disbursements hereunder may be made by Lender
upon the written request of any person who has been authorized by Borrowers to request such disbursements until such time as written notice of Borrowers’ revocation of such authority is received by Lender at the address shown in
Section 12.4. 

 Except as otherwise provided in the Loan Documents or as set forth in the Loan Budget in Column D,
“Borrowers’ Equity Contributed Upon Closing To Fund Estimated Cost Already Incurred In Relation to (C) Remaining Costs”, all of the Borrowers’ Funds which are deposited with Lender by Borrower pursuant to the Loan Documents,
shall be placed in the subaccount of the Guarantor Reserve Account with, and controlled by, Lender for disbursement under this Agreement and the Guarantor Cash Management Agreement. 

  

					
		 	21	  	Loan No. 1015003

	3.3	FUNDS TRANSFER DISBURSEMENTS. Borrowers hereby authorize Lender to disburse the proceeds of the Loan made by Lender or its affiliate in accordance with the Loan Documents and the terms of the Disbursement
Instruction Agreement, as amended or replaced from time to time in accordance with the terms thereof. 

  

	3.4	LOAN DISBURSEMENTS. 

  

	 	(a)	Initial Disbursement. Subject to the conditions set forth in Section 3.1(a) and this Section 3.4, the Initial Disbursement in an amount equal to $71,011,800 shall be disbursed on the
Effective Date less certain Lender fees, costs and expenses agreed to by Borrowers in accordance with a settlement statement approved by Lender and the Borrowers. 

 

	 	(b)	Subsequent Disbursements. 

  

	 	(i)	Subject to the conditions set forth in Section 3.1(b), this Section 3.4 and Section 3.5, following the Initial Disbursement, the undisbursed Commitment Amount shall be disbursed
in accordance with the terms and conditions of Exhibit D, subject to a retention in accordance with Section 3.6 hereof, by deposit into the Master Operating Account. Disbursements made after the deposit of Borrowers’
Funds shall be made first from the Guarantor Reserve Account until such designated Borrowers’ Funds therein are depleted in accordance with the Guarantor Cash Management Agreement. 

 

	 	(ii)	In no event will Lender make disbursements (A) more frequently than monthly, or (B) with respect to disbursements relating to the Construction Improvements, in excess of the percentage of construction
completed for such Construction Property as certified by Lender’s inspector. The maximum amount of advances which Borrowers may request for a Property or for any component or phase thereof shall be as set forth in the Property Level Budget for
such Property. 

  

	 	(iii)	Subject to the reallocations permitted by Lender pursuant to Section 3.5 hereof, Lender shall not be obligated to disburse Loan proceeds for the payment of any cost if the amount of such cost, together with
the amounts of other costs included within the same “line-item” in the Property Level Budget or Loan Budget, as applicable, for which requests for advances have previously been submitted and approved, exceeds the amount set forth in the
Property Level Budget or Loan Budget, as applicable, for such line-item. 

  

	 	(iv)	At its option, Lender may make disbursements to cover any expenses or charges which are to be borne by Borrowers, including, but not limited to, the cost of any required legal fees, appraisals, inspections,
certifications or surveys. In its reasonable judgment, Lender may make any disbursements by payment to Borrowers or jointly to Borrowers and any contractor, subcontractor, supplier, or other person performing work or furnishing materials in
connection with the construction of the Construction Improvements. All disbursements shall be applied by Borrowers solely for the purposes for which the funds have been disbursed. Developer’s fees payable to a developer that is not a Related
Person (unless such fees are payable to a Related Person pursuant to the “Interest Reserve, Advisory Fees, CF Shortfall Net of NOI Offsets” Line Item Loan Budget to be paid pursuant to the Advisory Agreement or otherwise approved by
Lender, all of which are hereby expressly permitted) will be disbursed pursuant to the applicable Development Agreement under the applicable Construction Property at the time of the requested advance. 

 

	 	(v)	 All disbursements shall be made first from Borrowers’ Funds and then from available Loan funds. In addition, the $6,000,000 in equity deposited
into the 

  

					
		 	22	  	Loan No. 1015003

	 	
Master Operating Account for the payment of items described in Column D of the Loan Budget (and as further described in the Property Level Budgets) shall be disbursed by Borrowers for the payment
of such costs prior to any Loan proceeds being disbursed for such items. 

  

	 	(vi)	If the outstanding principal balance of the Loan ever exceeds the maximum amount of the Loan, then all such amounts shall nonetheless be evidenced by the Note, guaranteed by the Guaranty and secured by the Security
Instruments; however, Borrowers shall, within five (5) Business Days after Lender’s demand or Borrowers’ earlier discovery of such advance, pay to Lender an amount equal to such excess principal amount and accrued but unpaid interest
thereon. 

  

	 	(vii)	All requests for advances shall clearly identify any amounts requested for payment to a Related Person. Unless expressly set forth in the then effective Loan Budget or this Agreement, no developer’s, management,
consulting or brokerage fee or commission, developer profit or other payment to any Related Person will be paid directly or indirectly from any proceeds of the Loan without Lender’s prior written approval. 

 

	 	(viii)	In addition to, and not in lieu of any condition set forth in this Section above, Lender shall have the right to condition any disbursement related to the Construction Improvements upon Lender’s receipt and
approval of the following: (A) bills, invoices, documents of title, vouchers, statements, payroll records, receipts and any other documents evidencing the total amount expended, incurred or due for any requested line-item in the Loan Budget;
(B) evidence of Borrowers’ use of a lien release, joint check and voucher system reasonably acceptable to Lender for payments or disbursements to any contractor, subcontractor, materialman, supplier or lien claimant;
(C) architect’s, Lender’s inspector’s periodic certifications of the percentage and/or stage of construction that has been completed for the applicable Construction Property and its conformance to the Plans and Specifications and
governmental requirements based upon any such Lender’s inspector’s periodic physical inspections of the Construction Properties; waivers and releases of any mechanics’ lien, stop payment notice claim, equitable lien claim or other
lien claim rights; and (D) any other document, requirement, update, evidence, endorsement, certification or information that Lender may request under any provision of the Loan Documents. 

 

	 	(c)	All disbursements shall be held by Borrowers in trust and applied by Borrowers solely for the purposes for which the funds have been disbursed. Lender has no obligation to monitor or determine Borrower’s use or
application of the disbursements. 

  

	3.5	REALLOCATIONS. Notwithstanding anything to the contrary contained herein, the Loan Budget represents an aggregate budget for the Properties, and Property Level Budgets totaling the amounts set forth in the
Loan Budget are attached as Exhibit I. Borrowers shall not be entitled to require that Lender reallocate Loan proceeds from any line item in any Property Level Budget or the Loan Budget to another line item except as follows. To the extent
true cost savings should be incurred with respect to any line item in a Property Level Budget, which such cost savings are verifiable by Lender in Lender’s sole but reasonable discretion, Borrowers may request that Lender reallocate such cost
savings (i) to one or more line items in the same Property Level Budget and, absent the then existence and continuance of a Default, Lender shall not withhold its consent to such reallocation, or (ii) to one or more line items in a
different Property Level Budget, such consent to be in Lender’s reasonable discretion. If any Loan proceeds are reallocated at the request of Borrowers and in accordance with this Section 3.5, then Exhibit C shall be
deemed amended in accordance with such reallocation. Lender reserves the right, at its option, while a Default exists, to disburse Loan proceeds allocated to any of the line items for such other purposes (including the payment of interest on the
Note) or in such different proportions as Lender may, in its sole discretion, deem necessary or advisable. 

  

					
		 	23	  	Loan No. 1015003

	3.6	WITHHOLDING OF ADVANCES; RETENTION. Lender may withhold advances with respect to the construction of the Construction Improvements under the following circumstances, in addition to the circumstances
described in Sections 11.2 and 11.5 hereof: 

  

	 	(a)	Lender may withhold any advance if the request therefor is not accompanied by executed statutory lien waivers for all work done by all applicable Major Subcontractors or General Contractor (on its behalf and on behalf
of all subcontractors) or from such other parties as required by the Title Company to issue any title endorsement required hereunder, equipment leased and materials supplied through the date of the immediately preceding request for an advance.

  

	 	(b)	Except as provided below, ten percent (10%) of each advance for hard costs shall be retained by Lender until (i) the applicable Architect has certified, and the Lender’s inspector has confirmed, on AIA
Form G704 or other appropriate form, that the relevant Construction Improvements have been substantially completed in accordance with the applicable Plans and Specifications; (ii) each applicable Governmental Authority shall have duly inspected
and approved the relevant Improvements and issued the appropriate temporary or permanent certificate of occupancy to evidence such approval or such other documentation issued by the applicable Governmental Authority to evidence such approval
reasonably acceptable to Lender; (iii) thirty (30) days shall have elapsed from the date of Completion of the Construction Improvements; and (iv) Lender has received the following endorsements to the applicable Title Policy in form
and content satisfactory to Lender: a date-down endorsement and other endorsements amending the mechanic’s and materialmen’s lien coverage and, if applicable, deleting the pending disbursements clause. The retainage portion of each advance
for labor, services and/or material will be disbursed following such timely Completion of the Construction Improvements unless Lender, in its sole discretion, agrees to disbursements at an earlier stage. Notwithstanding the foregoing, Lender agrees
that after construction of the Construction Improvements have reached fifty percent (50%) of Completion, as determined in the reasonable judgment of Lender, then Borrowers, at their option, may instruct Lender to make a disbursement from such
retainage in an amount specified by Borrowers, but in no event in an amount which would cause the retainage, after such disbursement, to be less than five percent (5%) of the total amount of all hard costs construction line items previously
disbursed, calculated as of the date of such instruction by Borrowers and with respect to each and every draw request funded thereafter. 

  

	 	(c)	Any one or more advances may be withheld in whole or in part if Lender determines that the requested advance(s) would cause the amount committed or advanced to exceed the limitations set forth in the then effective Loan
Budget or the limitations in Section 3.4. 

  

	3.7	TENANT IMPROVEMENTS / LEASING COMMISSIONS. Borrowers shall be entitled to receive aggregate advances, not to exceed the amounts set forth in the “Tenant Improvements” and “Leasing
Commissions” line items, respectively, of the Property Level Budget, each as applicable with respect to each Property, for the payment of Tenant Improvements and Leasing Commissions incurred (collectively, “TI/LC Expenses”) in
leasing space within such Property. Advances may be obtained by submitting to Lender a draw request otherwise complying with this Agreement, specifying the amount requested and the cost or costs to be paid with the requested funds, together with
such supporting invoices, lien waivers, certificates, affidavits and other supporting documents as Lender may reasonably request. Advances for the payment of Leasing Commissions with respect to a given project lease shall be payable: (a) fifty
percent (50%) upon execution of the lease; and (b) fifty percent (50%) upon the earlier of the (1) the first payment of rent under such lease or (2) delivery to Lender of an acceptable estoppel certificate signed by the
tenant following the tenant’s occupancy and opening for business. 

  

					
		 	24	  	Loan No. 1015003

	3.8	INTEREST RESERVE ADVANCES. At its option, Lender may make disbursements directly to Lender for the payment of interest which accrues and becomes due under the Note, if and to the extent the Loan Budget
includes a line-item for interest reserve advances. 

  

	3.9	LENDER’S OPTIONAL DISBURSEMENTS. During the occurrence and continuance of a Default, Lender may make disbursements to cover any expenses or charges which are to be borne by Borrowers, including, but
not limited to, the cost of any required legal fees, appraisals, inspections, certifications or surveys. Upon Borrowers’ request or during the occurrence and continuance of a Default, Lender may make any disbursements by payment to Borrowers or
jointly to Borrowers and a General Contractor, Architect, subcontractor, supplier, or other Person performing work or furnishing materials in connection with the construction of the Construction Improvements. All disbursements shall be applied by
Borrowers solely for the purposes for which the funds have been disbursed. 

 ARTICLE 4. CONSTRUCTION 

 

	4.1	COMMENCEMENT OF CONSTRUCTION. Borrowers shall (1) have commenced or will commence construction of the Construction Improvements with respect to the Bluegrass Valley II Property without delay after
recordation of the Security Instruments, (2) Complete construction of the Construction Improvements with respect to the Bluegrass Valley II Property, free and clear of any mechanics’ and materialmen’s liens and stop payment notices,
as applicable, in accordance with the Plans and Specifications and other provisions of the Loan Documents, with all construction costs having been paid, on or before the Original Maturity Date and (3) have commenced construction of the
Construction Improvements with respect to the Lehigh Valley II Property at least ninety (90) days prior to the Original Maturity Date (or, if the Borrowers exercise the Option to Extend, at such date as required pursuant to
Section 2.13(i) above). 

  

	4.2	COMPLETION OF CONSTRUCTION. Subject to Sections 4.1 and 4.3, Borrowers shall Complete construction of the Improvements (other than with respect to the Lehigh Valley II Property) on or before
the Original Maturity Date. 

  

	4.3	FORCE MAJEURE. The time within which construction of the Construction Improvements and, if permitted by the applicable Lease, each applicable Tenant Improvements, must be Completed shall be extended for a
period of time equal to the period of any delay directly affecting construction which is caused by fire, earthquake or other acts of God, strike, lockout, acts of public enemy, riot, insurrection, or governmental regulation of the sale or
transportation of materials, supplies or labor; provided, however, that Borrowers shall furnish Lender with written notice satisfactory to Lender evidencing any such delay within ten (10) days from the date any Borrower becomes
aware of the occurrence of any such delay. Other than with respect to the Lehigh Valley II Property, in no event shall the time for Completion thereof be extended beyond the earlier of (i) the Maturity Date or (ii) more than ninety
(90) days beyond the outside date for Completion as set forth in Section 4.2 above. 

  

	4.4	 CONSTRUCTION AGREEMENT. Prior to the commencement of any work, each Construction Borrower and applicable General Contractor shall have
entered into and delivered to Lender a Construction Agreement pursuant to the terms and conditions of which each such General Contractor is to construct the Construction Improvements and prior to any work on Tenant Improvements, each applicable
Borrower and the applicable Contractor shall have entered into and, if requested by Lender, delivered to Lender a Construction Agreement pursuant to the terms and conditions of which the applicable Contractor is to construct the applicable Tenant
Improvements. Borrower shall require each General Contractor, as to the Construction Improvements, and the applicable Contractor, as to the applicable Tenant Improvements, to perform in accordance with the terms of the applicable Construction
Agreement and shall not materially amend, modify or alter the responsibilities of such General Contractor or the other Contractors, as applicable, under the applicable Construction Agreement without Lender’s prior written consent. Promptly
following the later of the (a) Effective Date and (b) the execution of a 

  

					
		 	25	  	Loan No. 1015003

	 	
General Contract, each applicable Construction Borrower shall execute an assignment of such Borrower’s rights under the Construction Agreements to Lender as security for such Borrower’s
obligations under this Agreement and the other Loan Documents and shall cause the applicable General Contractor to consent to any such assignment pursuant to a Contractor’s Consent, in form and substance acceptable to Lender, and shall cause
each Contractor to consent to such assignment pursuant to a Contractor’s Consent in the form attached hereto as Exhibit G. Notwithstanding the foregoing, if requested by Lender, each applicable Borrower shall cause each Contractor
for any Tenant Improvements to execute and deliver to Lender a Contractor’s Consent in the form of Exhibit G hereto. 

  

	4.5	ARCHITECT’S AND DESIGN PROFESSIONAL’S AGREEMENT. Prior to the commencement of any work, each Construction Borrower and applicable Architect shall have entered into an Architect’s Agreement,
pursuant to which each such Architect designed the applicable Construction Improvements. In connection with each Approved Lease for which Tenant Improvements are to be constructed, each applicable Borrower and the applicable Design Professionals
shall have entered into a Design Professional Agreement, pursuant to which such Design Professional will design the Tenant Improvements. Each applicable Borrower shall require such Architect and Design Professionals to perform in accordance with the
terms of each applicable Architect’s Agreement and each applicable Design Professional Agreement, respectively, and shall not materially amend, modify or alter the responsibilities of such Architect and Design Professionals under each
Architect’s Agreement and each applicable Design Professional Agreement, respectively, without Lender’s prior written consent. Promptly following the later of the (a) Effective Date and (b) the execution of an Architect’s
Agreement or other Design Professional Agreement, each Construction Borrower shall execute an assignment of the Architect’s Agreements and all other Design Professional Agreements and the Plans and Specifications prepared by such Architect and
to be prepared by such Design Professionals, with respect to the Construction Improvements, to Lender as additional security for Borrowers’ performance under this Agreement and the other Loan Documents and shall cause each Architect to execute
and deliver to Lender an assignment of each applicable Design Professional’s Agreement, pursuant to those certain Architect’s Consents and Assignments of Design Professional Agreements and Plans and Specifications, in a form acceptable to
Lender, and each such Design Professional shall concurrently execute and deliver to Lender a Design Professional Consent, in the form of the Design Professional’s Consent attached hereto as Exhibit F. Notwithstanding the foregoing,
if requested by Lender, each applicable Borrower shall cause each Design Professional for any of the Tenant Improvements to execute and deliver to Lender a Design Professional Consent in the form of Exhibit F hereto. 

 

	4.6	PLANS AND SPECIFICATIONS. 

  

	 	(a)	Changes; Lender Consent. Prior to the commencement of construction on the Lehigh Valley II Property, Lender shall have reviewed and approved the Plans and Specifications for the Lehigh Valley II Property.
Except as otherwise provided in this Agreement, no Borrower shall make any changes in the Plans and Specifications without Lender’s prior written consent if such change: (i) constitutes a material change in the building material or
equipment specifications, or in the architectural or structural design, value or quality of any of the Construction Improvements; (ii) would result in a total increase of construction costs for the Improvements (whether by single change or
multiple changes) in excess of the greater of (A) $100,000.00 or (B) five percent (5%) of the total construction hard costs of the applicable Construction Improvements as reflected in the Loan Budget; (iii) would affect the
structural integrity, quality of building materials, or overall efficiency of operating systems of the Construction Improvements; or (iv) requires the approval of any tenant required under such applicable Lease or governmental authority.
Without limiting the above, Lender agrees that a Borrower may make minor changes in the Plans and Specifications without Lender’s prior written consent, provided that such changes do not violate any of the conditions specified herein. Borrowers
shall at all times maintain, for inspection by Lender, a full set of working drawings of the Constructions Improvements. 

  

					
		 	26	  	Loan No. 1015003

	 	(b)	Changes; Submission Requirements. Borrowers shall submit any proposed change in the applicable Plans and Specifications of the Construction Improvements requiring Lender’s consent to Lender at least
five (5) Business Days prior to the commencement of construction relating to such proposed change. Requests for any change which requires consent shall be accompanied by working drawings and a written description of the proposed change,
submitted on a change order form acceptable to Lender, signed by such Borrower and, if required by Lender, also by the applicable Architect and General Contractor. At its option, Lender may require the Borrowers to provide: (i) evidence
satisfactory to Lender of the cost and time necessary to complete the proposed change; (ii) a deposit in the amount of any increased costs into the Guarantor Reserve Account only if as a result of the funding, the Loan will be out of balance,
or Borrowers may pay the difference for such construction cost increase as a condition to any further advances by Lender hereunder for the Improvements; and (iii) a complete set of “as built” Plans and Specifications for the Completed
Improvements (if required by Lender). 

  

	 	(c)	Consent Process. Each Borrower acknowledges that Lender’s review of any changes and required consent may result in delays in construction and hereby consents to any such delays. Failure by Lender to
respond by either approving or disapproving a request submitted within five (5) Business Days of delivery of the request for consent or approval and all information required for the evaluation of such request constitutes Lender’s approval
of the item submitted for approval. 

  

	 	(d)	Final Plans and Specifications. Upon Completion of the Construction Improvements, Borrowers shall deliver to Lender within ten (10) days of receipt thereof from the applicable Architect a set of such
final “as built” Plans and Specifications. 

  

	4.7	CONTRACTOR/CONSTRUCTION INFORMATION. Within ten (10) days of Lender’s written request, Borrowers shall deliver to Lender from time to time in a form acceptable to Lender: (a) a list
detailing the name, address and phone number of each General Contractor and each Major Subcontractor to be employed or used for construction of the Construction Improvements and, if requested by Lender for any Tenant Improvements, any other
Contractor, together with the dollar amount, including changes, if any, of each contract for each General Contractor and each Major Subcontractor and other Contractors, and the portion thereof, if any, paid through the date of such list;
(b) copies of each contract for each General Contractor and each Major Subcontractor (to the extent available) and other Contractors (to the extent available) identified in such list, including any changes thereto; (c) a cost breakdown of
the projected total cost of constructing the Construction Improvements or Tenant Improvements, as applicable, and that portion, if any, of each cost item which has been incurred; and (d) a construction progress schedule detailing the progress
of construction and the projected sequencing and completion time for uncompleted work, all as of the date of such schedule. 

Lender acknowledges that R.S. Mowery & Sons, Inc., The Conlan Company and Butters Construction & Development, Inc. are
approved as Contractors; provided, however, that such approval shall not constitute a warranty of qualification by Lender. Lender may contact any Contractor to discuss the course of construction provided Borrower receives notice of
such contact. 
  

	4.8	PROHIBITED CONTRACTS. Without Lender’s prior written consent, no Borrower shall contract for any materials, furnishings, equipment, fixtures or other parts or components of the Construction
Improvements, if any third party shall retain any ownership interest (other than lien rights created by operation of law) in such items after their delivery to a Construction Property. Such Borrower shall have five (5) days to effect the
removal of any such retained interest. 

  

	4.9	 LIENS AND NOTICES. If a lien affidavit is recorded or a notice of claim for unpaid work, materials or specially fabricated items or a
notice of a contractual retainage claim is given to the any Borrower or Contractor which affects any Property, such Borrower shall, within thirty (30) 

  

					
		 	27	  	Loan No. 1015003

	 	
calendar days of such recording or receipt of such notice or within five (5) calendar days of Lender’s demand, whichever occurs first: (a) pay and discharge the lien claim;
(b) effect the release thereof by recording or delivering to Lender a surety bond in sufficient form and amount; or (c) provide Lender with other assurances which Lender deems, in its reasonable discretion, to be necessary for the contest
and payment of such lien claim and for the full and continuous protection of Lender from the effect of such lien claim. 

  

	4.10	CONSTRUCTION RESPONSIBILITIES. Construction Borrowers shall construct or cause to be constructed the Construction Improvements in a workmanlike manner according to the applicable Plans and Specifications.
Construction Borrowers shall comply in all material respects with the applicable construction schedule furnished to Lender and shall comply with all applicable laws, ordinances, rules, regulations, building restrictions, recorded covenants and
restrictions, and requirements of all regulatory authorities having jurisdiction over the Property or Improvements. Each portion and all of the Construction Improvements, except for approved off-site improvements, shall be constructed within
building restriction and set-back lines, and shall not encroach upon, overhang or interfere with any easement, right-of-way, floodplain or other property. Construction Borrowers shall not commence the construction of any improvements on the
Construction Property, except for those set forth in the applicable Plans and Specifications, without Lender’s prior written consent (not to be unreasonably withheld, conditioned or delayed). Borrowers shall be solely responsible for all
aspects of Borrowers’ business and conduct in connection with the Properties, including, without limitation, for the quality and suitability of the Plans and Specifications and their compliance with Applicable Laws, the supervision of the work
of construction, the qualifications, and performance of all architects, engineers, contractors, material suppliers, consultants and property managers, and the accuracy of all applications for payment and the proper application of all disbursements.
Lender is not obligated to supervise, inspect or inform any Borrower or any third party of any aspect of the construction of the Construction Improvements or any other matter referred to above. 

 

	4.11	ASSESSMENTS AND COMMUNITY FACILITIES DISTRICTS. Without Lender’s prior written consent, no Borrower shall cause or suffer to become effective or otherwise consent to the formation of any assessment
district or community facilities district which includes all or any part of any Property pursuant to: (a) contractual agreements among property owners and/or other governmental or quasi-governmental
agencies or political subdivisions or districts, or other entity providing such community facilities; or (b) any state, county or municipal ordinance, law, regulation or statute. Nor shall any Borrower cause or otherwise consent to the levying
of special taxes or assessments against any Property by any such assessment district or community facilities district. 

  

	4.12	DELAY. Borrowers shall promptly notify Lender in writing of any event causing material delay or interruption of construction, or the timely completion of construction. The notice shall specify the
particular work delayed, and the cause and period of each delay. 

  

	4.13	 INSPECTIONS. In connection with any request for a disbursement of the Loan related to construction of the Construction Improvements or
any Tenant Improvements, Lender or its agent shall have the right to inspect and approve in accordance with the terms hereunder the Tenant Improvements and Construction Improvements and the construction work thereof prior to and as a condition
precedent to disbursing any such Loan proceeds. Subject to the rights of tenants under Approved Leases and upon reasonable prior notice to the applicable Borrower, Lender and its employees and its agent shall have the right to enter upon a Property
at all reasonable times from time to time (including with respect to clause (b) herein, whether before or after the commencement of a foreclosure proceeding) to inspect (a) the Tenant Improvements, (b) the Construction
Improvements and the construction work related to the Construction Improvements to verify information disclosed or required pursuant to this Agreement and (c) a Property for the purpose of determining the existence, location, nature and
magnitude of any past or present release or threatened release of any Hazardous Materials (as defined in the Hazardous Materials Indemnity Agreement) into, onto, beneath or from such Property. Any inspection or review of the

  

					
		 	28	  	Loan No. 1015003

	 	
Improvements by Lender with regard to clause (a) above is solely to determine whether Borrowers are properly discharging their obligations to Lender and may not be relied upon by
Borrowers or by any third party as a representation or warranty of compliance with this Agreement or any other agreement. Lender owes no duty of care to Borrowers or any third party to protect against, or to inform Borrowers or any third party of,
any negligent, faulty, inadequate or defective design or construction of the Construction Improvements as determined by Lender. All inspection costs of Lender shall be at Borrowers’ cost and expense. 

 

	4.14	SURVEYS. Upon Lender’s written request, Borrowers shall promptly deliver to Lender: (a) a perimeter survey of each Construction Property; (b) upon completion of the foundations of the
applicable Construction Improvements, a survey showing the location of such Construction Improvements on the applicable Construction Property and confirming that the Construction Improvements are located entirely within the applicable Construction
Property and do not encroach upon any easement, or breach or violate any governmental requirement; and (c) upon completion of the Construction Improvements, an as-built survey of the applicable Construction Property. All such surveys shall be
performed and certified by a licensed engineer or surveyor acceptable to Lender and the Title Company, shall be prepared according to current ALTA/ACSM Minimum Standard Detail Requirements and any additional items required by Lender or the Title
Company, and shall be certified to Lender and the Title Company. 

  

	4.15	IN BALANCE PAYMENTS. The Loan shall at all times be In-Balance. If Lender determines at any time that the Loan is not In-Balance, then Borrowers shall deposit the necessary In-Balance Payments with Lender
in the Guarantor Reserve Account following Lender’s written demand and prior to the next draw request. 

 ARTICLE 5.
INSURANCE 
 Borrowers shall, while any obligation of any Borrower or the Guarantor under any of the Loan Documents remains outstanding, maintain at
Borrowers’ sole expense, with licensed insurers approved by Lender, the following policies of insurance with respect to each Property in form and substance satisfactory to Lender. Capitalized terms used in this Article shall have the same
meaning as such terms are commonly and presently defined in the insurance industry. 
  

	5.1	TITLE INSURANCE. A Title Policy, together with any endorsements which Lender may require, insuring Lender, in the principal amount of the Loan, of the validity and the priority of the lien of the Security
Instruments upon the Properties, subject only to matters approved by Lender in writing. During the term of the Loan, Borrowers shall deliver to Lender, within five (5) days of Lender’s written request, such other endorsements to the Title
Policy as Lender may require. 

  

	5.2	PROPERTY INSURANCE. A Builders All Risk/Special Form Completed Value (Non-Reporting Form) Hazard Insurance policy, including, without limitation, theft coverage and such other coverages and endorsements as
Lender may require, insuring Lender against damage to the Property and Improvements in an amount not less than one hundred percent (100%) of the full replacement cost at the time of Completion of the Improvements. Such coverage should
adequately insure any and all Loan collateral, whether such collateral is onsite, stored offsite or otherwise. 

  

	5.3	FLOOD HAZARD INSURANCE. A policy of flood insurance, as deemed necessary by Lender, in an amount required by Lender, but in no event less than the amount sufficient to meet the requirements of
applicable law and governmental regulation, but in no event more than the maximum limit available under the National Flood Insurance Act. 

  

	5.4	 LIABILITY INSURANCE. A policy of commercial general liability insurance on an occurrence basis, with a combined limit of not less than
$5,000,000 in the aggregate and for each occurrence, insuring against liability for injury and/or death to any person and/or damage to any property occurring on the Property and/or in the Improvements. During the period of any

  

					
		 	29	  	Loan No. 1015003

	 	
construction, Borrowers shall cause its contractors and/or subcontractors to maintain in full force and effect any or all of the liability insurance required hereunder. Lender may require that
Lender be named as an additional insured on any such policy. Whether any Borrower employs a general contractor or performs as owner-builder, Lender may require that coverage include statutory workers’ compensation insurance. 

 

	5.5	OTHER COVERAGE. Borrowers shall provide to Lender evidence of such other reasonable insurance in such reasonable amounts as Lender may from time to time request against such other insurable hazards
with respect to a Property or Properties which at the time are required to be insured against by Lender in accordance with commercially reasonable market standards for property similar to the subject Property located in or around the region in which
the subject Property is located. Such coverage requirements may include, but are not limited to, coverage for earthquake, wind, acts of terrorism, mold, business income, delayed business income, rental loss, sink hole, soft costs, tenant improvement
or environmental. 

  

	5.6	GENERAL. Borrowers shall provide to Lender insurance certificates or other evidence of coverage in form acceptable to Lender, with coverage amounts, deductibles, limits and retentions as required by
Lender. All insurance policies shall provide that the coverage shall not be cancelable without ten (10) days prior written notice to Lender of any cancellation for nonpayment of premiums, and not less than thirty (30) days prior written
notice to Lender of any other cancellation. Borrowers shall provide notice of any modification that constitutes a reduction in coverage. Lender shall be named under a Lender’s Loss Payable Endorsement or a Standard Mortgagee Clause (in form
acceptable to Lender) on all insurance policies which each Borrower actually maintains with respect to the Property. All insurance policies shall be issued and maintained by insurers approved to do business in the state in which the Property is
located and must have an A.M. Best Company financial rating and policyholder surplus of “A-VI” or better. 

  

	5.7	COLLATERAL PROTECTION INSURANCE NOTICE. (A) EACH BORROWER IS REQUIRED TO: (i) KEEP THE PROPERTIES AND IMPROVEMENTS INSURED AGAINST DAMAGE IN THE AMOUNT SPECIFIED BY LENDER PURSUANT TO THE TERMS
HEREOF; (ii) PURCHASE THE INSURANCE FROM AN INSURER THAT IS AUTHORIZED TO DO BUSINESS IN THE STATE WHERE ANY SUCH PROPERTY IS LOCATED OR AN ELIGIBLE SURPLUS LINES INSURER; AND (iii) NAME LENDER AS THE PERSON TO BE PAID UNDER THE POLICY IN
THE EVENT OF A LOSS; (B) BORROWERS MUST, IF REQUIRED BY LENDER, DELIVER TO LENDER A COPY OF THE POLICY AND PROOF OF THE PAYMENT OF PREMIUMS THEREFOR; AND (C) IF BORROWERS FAILS TO MEET ANY REQUIREMENT LISTED IN CLAUSES (A) OR
(B) HEREOF, LENDER MAY OBTAIN COLLATERAL PROTECTION INSURANCE ON BEHALF OF BORROWERS AT BORROWERS’ EXPENSE. 

ARTICLE 6. REPRESENTATIONS AND WARRANTIES 

As a material inducement to Lender’s entry into this Agreement, each Borrower represents and warrants to Lender as of the Effective Date and continuing
thereafter that: 
  

	6.1	AUTHORITY/ENFORCEABILITY. Each Borrower is in compliance, in all material respects, with all laws and regulations applicable to its organization, existence and transaction of business and has all necessary
rights and powers and organizational authority to borrow, own, improve and operate the Properties and Improvements as contemplated by the Loan Documents. 

  

	6.2	BINDING OBLIGATIONS. Each Borrower is authorized to execute, deliver and perform its obligations under the Loan Documents, and such obligations shall be valid and binding obligations of such
Borrower. 

  

	6.3	 FORMATION AND ORGANIZATIONAL DOCUMENTS. Borrowers have delivered to Lender all formation and organizational documents of Borrowers,
Guarantor and Indemnitor, and each of their respective Constituent Entities, and all such formation and organizational documents remain 

  

					
		 	30	  	Loan No. 1015003

	 	
in full force and effect and have not been amended or modified since they were delivered to Lender. Borrowers shall not and shall not allow Guarantor and Indemnitor and any of their respective
Constituent Entities to amend, supplement or restate any of such formation and organizational documents if it would have a Material Adverse Effect. Borrowers shall immediately provide Lender with copies of any amendments, supplements or restatements
of the formation or organizational documents of any Borrower, Guarantor and Indemnitor. A true and accurate organizational chart showing the direct and indirect owners of Borrower is attached hereto as Schedule 6.3. 

 

	6.4	NO VIOLATION. Borrowers’ execution, delivery, and performance under the Loan Documents do not: (a) require any consent or approval not heretofore obtained under any partnership agreement,
operating agreement, articles of incorporation, bylaws or other document; (b) violate any governmental requirement applicable to any Property and Improvements or any other statute, law, regulation or ordinance or any order or ruling of any
court or governmental entity; (c) conflict with, or constitute a breach or default or permit the acceleration of obligations under any agreement, contract, lease, or other document by which any Borrower is or any Property and Improvements are
bound or regulated; or (d) violate any statute, law, regulation or ordinance, or any order of any court or governmental entity. 

  

	6.5	COMPLIANCE WITH LAWS; USE. Borrowers have, and at all times shall have obtained (when necessary and applicable), all permits, licenses, exemptions, and approvals necessary to construct, occupy, operate and
market the Properties and Improvements, and shall maintain compliance with all governmental requirements applicable to the Properties and Improvements and all Applicable Laws necessary for the transaction of its business, other than de minimis
non-compliance, and shall require its lessees or licensees to do the same. Each Property is one or more parcels, each lawfully created in compliance with all subdivision laws and ordinances, and is in compliance with applicable zoning laws for the
stated use of the Property and Improvements as disclosed to Lender at the time of execution hereof. 

  

	6.6	LITIGATION. Except as disclosed in Schedule 6.6 attached hereto, there are no claims, actions, suits, or proceedings pending, or to any Borrower’s knowledge threatened, against any
Borrower or affecting any Property that could have a Material Adverse Effect. 

  

	6.7	FINANCIAL CONDITION. The financial statements of Borrowers (including operating statements for each Property) and Guarantor heretofore and hereafter delivered to Lender by Borrowers or Guarantor are or
will (i) be materially complete and correct, (ii) present fairly and accurately the financial condition of such party, (iii) disclose all liabilities that are required by the Liquidation Basis Accounting (GAAP) consistently applied,
to be reflected or reserved against, and (iv) be prepared in accordance with the same accounting standard used by Borrowers or Guarantor to prepare the financial statements delivered to and approved by Lender in connection with the making of
the Loan, or other accounting standards approved by Lender. Since the date of such financial statements, there has been no change in such financial condition which could reasonably be expected to have a Material Adverse Effect, nor has any asset or
properties reflected on such financial statement been sold, transferred, assigned mortgaged, pledged or encumbered which would have a Material Adverse Effect, except as previously disclosed in writing by Borrowers or Guarantor to Lender. Each
Borrower acknowledges and agrees that Lender may request and obtain additional information from third parties regarding any of the above, including, without limitation, credit reports. 

 

	6.8	NO MATERIAL ADVERSE CHANGE. There has been no material adverse change in the financial condition of any Borrower and/or Guarantor since the dates of the latest financial statements furnished to Lender and,
except as otherwise disclosed to Lender in writing, no Borrower has entered into any material transaction which is not disclosed in such financial statements and which could have a Material Adverse Effect. 

  

					
		 	31	  	Loan No. 1015003

	6.9	LOAN PROCEEDS AND ADEQUACY. The undisbursed Loan proceeds, together with Borrowers’ Funds and all other sums provided by Borrowers are sufficient to construct the Construction Improvements and Tenant
Improvements in accordance with the terms and conditions of this Agreement. 

  

	6.10	ACCURACY. To the best of each Borrower’s knowledge, all reports, documents, instruments and written information delivered by Borrowers or Guarantor to Lender in connection with the Loan, as of the
date delivered: (i) are correct in all material respects and sufficiently complete to give Lender accurate knowledge of their subject matter thereof; and (ii) do not contain any material misrepresentation of a material fact or omission of
a material fact which omission makes the provided information misleading in any material respect. 

  

	6.11	TAX LIABILITY. Each Borrower has filed all required federal, state, county and municipal tax returns and has paid all taxes and assessments owed and payable, and no Borrower has knowledge of any basis for
any additional payment with respect to any such taxes and assessments. 

  

	6.12	UTILITIES. All utility services, including, without limitation, gas, water, sewage, electrical and telephone, necessary for the operation and occupancy of each Property are available at or within the
boundaries of such Property. 

  

	6.13	COMPLIANCE. Each Borrower is familiar with and in compliance with all governmental requirements for the ownership, occupancy and operation of the Properties and will conform to and comply with all
governmental requirements and the Plans and Specifications. 

  

	6.14	AMERICANS WITH DISABILITIES ACT COMPLIANCE. The Construction Improvements have been designed and constructed and completed, and will hereafter be maintained, and any Construction Improvements will be
designed, constructed and maintained, in compliance with all of the requirements of the ADA, and with any and all similar Applicable Laws of the State where any such Property is located, as each may be amended from time to time. Borrowers shall be
responsible for all ADA compliance costs. 

  

	6.15	BUSINESS LOAN. The Loan is a business loan transaction in the stated amount solely for the purpose of carrying on the business of Borrowers and none of the proceeds of the Loan will be used for the
personal, family or agricultural purposes of any Borrower. 

  

	6.16	TAX SHELTER REGULATIONS. Neither any Borrower nor Guarantor, nor any subsidiary of any of the foregoing intends to treat the Loan or the transactions contemplated by this Agreement and the other Loan
Documents as being a “reportable transaction” (within the meaning of Treasury Regulation Section 1.6011-4). If Borrowers, or any other party to the Loan determines to take any action
inconsistent with such intention, Borrowers will promptly notify Lender thereof. If any Borrower so notifies Lender, Borrowers acknowledge that Lender may treat the Loan as part of a transaction that is subject to Treasury Regulation Section 301.6112-1, and Lender will maintain the lists and other records, including the identity of the applicable party to the Loan as required by such Treasury Regulation. 

 

	6.17	FULL FORCE AND EFFECT. The Note and other Loan Documents are in full force and effect without any defense, counterclaim, right or claim of set-off; all necessary action to authorize the execution and
delivery of this Agreement has been taken. 

  

	6.18	NO SUBORDINATION. There is no agreement, indenture, contract or instrument to which any Borrower is a party or by which any Borrower may be bound that requires the subordination in right of payment of any
of Borrowers’ obligations under this Agreement to any other obligation of any Borrower. 

  

					
		 	32	  	Loan No. 1015003

	6.19	PERMITS; FRANCHISES. Borrowers possesses, and will hereafter possess, all permits, memberships, franchises, contracts and licenses required and all trademark rights, trade names, trade name rights,
patents, patent rights and fictitious name rights necessary to enable it to conduct the business in which it is now engaged without conflict with the rights of others. 

 

	6.20	OTHER OBLIGATIONS. Borrowers are not in default (beyond applicable notice and cure periods) on any obligation for borrowed money, any purchase money obligation or any other material lease, commitment,
contract, instrument or obligation, which default shall result in a loss, payment or liability in excess of (i) $500,000 for all such defaults applicable to a single Property or (ii) $1,500,000, in the aggregate for such defaults with
respect to all the Properties; provided, however, Borrowers will not be deemed to be in default if Borrowers are engaged in and diligently pursuing in good faith proceedings appropriate to contest the validity or amount of such
obligation. 

  

	6.21	LEASES. The Schedule of Leases attached hereto as Schedule 6.22 is, as of the date hereof, a true, accurate and complete list of all Leases. 

 

	6.22	MATERIAL CONTRACTS. As of the date hereof, no Material Contracts affect any Property. 

  

	6.23	SANCTIONS. (a) No Person within the Borrowing Group is or will be a Sanctioned Person; (b) no Person within the Borrowing Group is or will be controlled by or is acting on behalf of a Sanctioned
Person; (c) no Person within the Borrowing Group is under investigation for an alleged breach of Sanction(s) by a governmental authority that enforces Sanctions; (d) no Person within the Borrowing Group will use any of the Loan proceeds
for the purpose of: (i) providing financing to or otherwise making funds directly or indirectly available to any Sanctioned Person; or (ii) providing financing to or otherwise funding any transaction which would be prohibited by Sanctions
or would otherwise cause the Lender or any other party to this Agreement, or any entity affiliated with any such party, to be in breach of any Sanction; (e) no Person within the Borrowing Group will fund any repayment of the Loan with proceeds
derived from any transaction that would be prohibited by Sanctions or would otherwise cause the Lender or any other party to this Agreement, or any entity affiliated with any such party, to be in breach of any Sanction; (f) Borrower will ensure
that appropriate controls and safeguards are in place to fully comply with this Section and the Borrower will notify the Lender in writing not more than three (3) Business Day after becoming aware of any breach of this Section.

  

	6.24	PROJECT INFORMATION. (a) The recitals described in this Agreement with respect to the project are true and correct; (b) each Property includes, or will include upon the Completion of
construction, adequate on-site parking to comply with Applicable Laws; (c) each the Property currently abuts and has paved access to, or will have paved access to a completed and dedicated public thoroughfare; (d) all water, sewer, natural
gas (if applicable), electricity, refuse collection and telephone service, and police and fire protection, necessary for construction of the Construction Improvements, and operation of each Property after Completion, are available or will be
available upon the Completion of construction, and Borrowers will cause such utilities to be installed and connected to each Property, to the extent not already installed and connected; and (e) no Borrower has knowledge that any archaeological
ruins, discoveries or specimens exist on any Property. 

  

	6.25	 REAFFIRMATION AND SURVIVAL OF REPRESENTATIONS AND WARRANTIES. Each request by Borrowers for an advance under this Agreement shall
constitute an affirmation on the part of each Borrower that the representations and warranties contained in this Agreement and the other Loan Documents given in connection with the Loan are true and correct in all material respects (or, in the case
of any representation or warranty expressly qualified by materiality or Material Adverse Effect, in all respects) on and as of such date of such borrowing with the same effect as though made on and as of such date, except to the extent such
representations and warranties expressly relate to an earlier date, in which case such representations and warranties shall have been true and correct in all material respects (or, in the case of any representation or

  

					
		 	33	  	Loan No. 1015003

	 	
warranty expressly qualified by materiality or Material Adverse Effect, in all respects) as of such earlier date. All representations and warranties made herein shall survive the execution of
this Agreement, the making of all advances hereunder and the execution and delivery of all other documents and instruments in connection with the Loan, so long as Lender has any commitment to lend to Borrowers hereunder and until the Loan has been
paid in full. 

 ARTICLE 7. REPRESENTATIONS, WARRANTIES AND COVENANTS REGARDING 

SPECIAL PURPOSE ENTITY STATUS 
  

	7.1	REPRESENTATIONS, WARRANTIES AND COVENANTS REGARDING SPECIAL PURPOSE ENTITY (“SPE”) STATUS. Each Borrower hereby represents, warrants and covenants to Lender, with regard to each such Borrower, as
follows: 

  

	 	(a)	Limited Purpose. The sole purpose to be conducted or promoted by any Borrower since its organization is to engage in the following activities: (i) to acquire, own, hold, lease, operate, manage,
maintain, develop and improve, the applicable Property and, if applicable, construct the Construction Improvements; (ii) to enter into and perform its obligations under the Loan Documents; (iii) to sell, transfer, service, convey, dispose
of, pledge, assign, borrow money against, finance, refinance or otherwise deal with each Property to the extent permitted under the Loan Documents; and (iv) to engage in any lawful act or activity and to exercise any powers permitted to limited
liability companies organized under the laws of the State of Delaware that are related or incidental to and necessary, convenient or advisable for the accomplishment of the above mentioned purposes. 

 

	 	(b)	Limitations on Debt, Actions. Except as expressly permitted in the Loan Documents and notwithstanding anything to the contrary in any other document governing the formation, management or operation of each
Borrower, no Borrower shall (i) guarantee any obligation of any Person, including any Affiliate, or become obligated for the debts of any other Person or hold out its credit as being available to pay the obligations of any other Person;
(ii) engage, directly or indirectly, in any business other than as required or permitted to be performed under this Section 7.1; (iii) incur, create or assume any indebtedness or liabilities other than (A) the Loan;
(B) any Swap Agreement between Borrower and Lender; (C) taxes applicable to the applicable Property; (D) any Permitted Debt; and (E) tenant improvement and leasing commission liability, which are not financed outside this Loan;
(iv) make or permit to remain outstanding any loan or advance to, or own or acquire any stock or securities of, any Person, except that a Borrower may invest in those investments permitted under the Loan Documents; (v) to the fullest
extent permitted by law, engage in any dissolution, liquidation, consolidation, merger, sale or other transfer of any of its assets outside the ordinary course of Borrower’s business; (vi) buy or hold evidence of indebtedness issued by any
other Person (other than cash or investment-grade securities); (vii) form, acquire or hold any subsidiary (whether corporate, partnership, limited liability company or other) or own any equity interest in any other entity; (vii) own any
asset or property other than the Properties and incidental personal property necessary for the ownership or operation of the Properties; or (viii) take any material action without the written approval of all members and general partners, as
applicable, whose approval is required by the organizational documents of each Borrower. 

  

	 	(c)	 Separateness Covenants. In order to maintain its status as a separate entity and to avoid any confusion or potential consolidation with
any Affiliate, each Borrower represents and warrants that in the conduct of its operations since its organization has and will continue to observe the following covenants (collectively, the “Separateness Provisions”):
(i) maintain books and records and bank accounts separate from those of any other Person; (ii) maintain its assets in such a manner that it is not costly or difficult to segregate, identify or ascertain such assets; (iii) comply with
all organizational 

  

					
		 	34	  	Loan No. 1015003

	 	
formalities necessary to maintain its separate existence; (iv) hold itself out to creditors and the public as a legal entity separate and distinct from any other entity; (v) maintain
separate financial statements, showing its assets and liabilities separate and apart from those of any other Person and not have its assets listed on any financial statement of any other Person except that Borrower’s assets may be included in a
consolidated financial statement of its Affiliate so long as appropriate notation is made on such consolidated financial statements to indicate the separateness of each Borrower from such Affiliate and to indicate that such Borrower’s assets
and credit are not available to satisfy the debts and other obligations of such Affiliate or any other Person, except as contemplated by the Loan Documents; (vi) prepare and file its own tax returns separate from those of any Person to the
extent required by applicable law, and pay any taxes required to be paid by applicable law; (vii) allocate and charge fairly and reasonably any common employee or overhead shared with Affiliates; (viii) not enter into any transaction with
any Affiliate, except on an arm’s-length basis on terms which are no less favorable than would be available for unaffiliated third parties, and pursuant to written, enforceable agreements; (ix) conduct business in its own name, and to the
extent any Borrower uses stationery, invoices or checks, use separate stationery, invoices and checks bearing its own name; (x) not commingle its assets or funds with those of any other Person; (xi) except as contemplated by the Loan
Documents, not assume, guarantee or pay the debts or obligations of any other Person; (xii) correct any known misunderstanding as to its separate identity; (xiii) not permit any Affiliate to guarantee or pay its obligations (other than
limited guarantees and indemnities set forth in the Loan Documents); (xiv) not make loans or advances to any other Person; (xv) pay its liabilities and expenses out of and to the extent of its own funds; (xvi) intentionally omitted;
and (xvii) maintain adequate capital in light of its contemplated business purpose, transactions and liabilities; provided, however, that the foregoing shall only apply to the extent that there is positive net cash flow at the Properties after
the payment of all operating expenses and debt service on the Loan, and shall not require any equity owner to make additional capital contributions to Borrowers. 

Failure of any Borrower to comply with any of the covenants contained in this Section or any other covenants contained in this Agreement shall
not affect the status of such Borrower as a separate legal entity. 
  

	 	(d)	SPE Covenants in Borrower Organizational Documents. Each Borrower covenants and agrees to incorporate the provisions contained in this Section into such Borrower’s organizational documents and such
Borrower agrees not to amend, modify or otherwise change its organizational documents with respect to the provisions of this Section without the prior written consent of the Lender. 

ARTICLE 8. HAZARDOUS MATERIALS 
  

	8.1	HAZARDOUS MATERIALS INDEMNITY AGREEMENT. Simultaneously herewith, Borrowers and Guarantor have executed and delivered to Lender the Hazardous Materials Indemnity Agreement, which Hazardous Materials
Indemnity Agreement is not secured by the Security Instrument. 

 ARTICLE 9. COVENANTS OF BORROWERS 

 

	9.1	 EXPENSES. Borrowers shall promptly pay Lender following receipt of written request therefor all actual out-of-pocket costs and expenses
incurred by Lender in connection with: (a) the preparation of this Agreement, all other Loan Documents and Other Related Documents contemplated hereby; (b) any modifications and amendments, if any, of this Agreement, any of the Other Loan
Documents or any Other Related Documents; (c) the processing of any Borrower or Guarantor requests made hereunder, under any of the other Loan Documents and under any Other Related Document; (d) the enforcement or satisfaction by Lender of
any of Borrowers’ 

  

					
		 	35	  	Loan No. 1015003

	 	
obligations under this Agreement, the other Loan Documents and Other Related Documents; or (e) otherwise protecting Lender’s interests under this Agreement, any other Loan Document and
any Other Related Documents, including, without limitation, in connection with any “work-out” of the Loan or any bankruptcy, insolvency, receivership, reorganization, rehabilitation, liquidation or other similar proceeding in respect of
any Loan Party or an assignment by any Loan Party for the benefit of its creditors. For all purposes of this Agreement, Lender’s costs and expenses shall include, without limitation, all (in each case, reasonable except in the event a Default
exists) appraisal fees, cost engineering, monthly inspection fees, legal fees and expenses, accounting fees, environmental consultant fees, auditor fees, recording taxes, recording fees, filing fees, UCC filing fees and/or UCC vendor fees, flood
certification vendor fees, tax service vendor fees, and the cost to Lender of any title insurance and endorsement premiums, title surveys, release and notary fees. Borrowers recognizes and agree that formal written appraisals of the Property by a
licensed independent appraiser may be required by Lender’s internal procedures and/or federal regulatory reporting requirements on an annual and/or specialized basis and that Lender may, at its option, require inspection of the Property and
Construction Improvements by an independent supervising architect and/or cost engineering specialist: (i) prior to each advance; (ii) at least once each month during the course of construction even though no disbursement is to be made for
that month; (iii) upon completion of all Construction Improvements; and (iv) at least annually thereafter; however such Appraisals shall be obtained at Lender’s sole cost other than (A) the Appraisal obtained in connection with
approval of the Loan and approval of each option to extend the term of the Loan, (B) Appraisal obtained by reason of any regulatory requirements imposed on Lender, and (C) any Appraisal obtained during the existence of a Default. If any of
the services described above are provided by an employee of Lender or its affiliates, Lender’s costs and expenses for such services shall be calculated in accordance with Lender’s standard charge for such services. 

 

	9.2	ERISA COMPLIANCE. Borrowers shall at all times comply with the provisions of the Employment Retirement Income Security Act of 1974, as amended from time to time, including all regulations promulgated and
case law thereunder (“ERISA”) with respect to any retirement or other employee benefit plan to which it is a party as employer, and as soon as possible after any Borrower knows, or has reason to know, that any Reportable Event (as
defined in ERISA) with respect to any such plan of such Borrower has occurred, it shall furnish to Lender a written statement setting forth details as to such Reportable Event and the action, if any, which Borrower proposes to take with respect
thereto, together with a copy of the notice of such Reportable Event furnished to the Pension Benefit Guaranty Corporation. 

  

	9.3	LEASING. Borrowers shall use commercially reasonable efforts to maintain all leasable space in the Properties leased at no less than fair market rental rates. 

 

	9.4	APPROVAL OF LEASES. No Borrower shall execute any Lease (including any renewals or material modifications or amendments) for all or any part of any Property unless same is an Approved Lease. Except for
Deemed Approved Leases, Lender shall approve or disapprove any proposed Lease submitted by a Borrower within ten (10) days after such Borrower has submitted to Lender each of the following (collectively, the “Approval
Information”): (i) a written request for approval, (ii) the proposed form of Lease (with any changes from the Approved Lease Form marked or redlined), and (iii) financial and background information regarding the proposed
tenant and such other information reasonably requested by Lender. Provided no Default exists, any action with respect to any proposed Lease requiring Lender’s consent shall be deemed approved by Lender if Lender does not approve or disapprove
any requested action within ten (10) Business Days after receipt by Lender of the Approval Information. Any such notice given by a Borrower under this Section 9.4 shall include in large, bold text: “THIS IS A REQUEST FOR
LEASE APPROVAL. IF YOU DO NOT RESPOND WITHIN TEN (10) BUSINESS DAYS, YOU SHALL BE DEEMED TO HAVE APPROVED THIS REQUEST.” All Lease terminations (i) effective prior to the Lease expiration date or (ii) triggered for reasons
other than an uncured default thereunder shall be subject to the prior written consent of Lender, which consent shall not be unreasonably withheld, conditioned or delayed. Any material change to the Approved Lease Form shall be subject to the prior
written consent of Lender, which consent shall not be unreasonably withheld, conditioned or delayed. 

  

					
		 	36	  	Loan No. 1015003

	9.5	SNDA Delivery. In the event Lender requires a subordination, non-disturbance and attornment agreement in a form acceptable to Lender (“SNDA”) in connection with any one or more Leases of
any Property, Borrowers shall use commercially reasonably efforts to deliver to Lender in recordable form, with property notary acknowledgements attached, the executed, unmodified originals of any such SNDA within thirty (30) days of
Lender’s request for same. Each Borrower hereby acknowledges that Lender’s delivery of any such SNDA to a Borrower for execution shall be deemed equivalent to Lender’s written notice requesting the same of Borrowers.

  

	9.6	DISTRIBUTIONS. In no event shall any operating income of any Borrower be distributed to any partner, venturer, member or equity investor of Borrower during the occurrence and continuance of a Default.
Notwithstanding the foregoing, in the event any fees are not paid under the Advisory Agreement during the occurrence and continuance of a Default by reason of this Section (“Unpaid Advisory Fees”), then upon the cure of such
Default, as confirmed by Lender acting reasonably in writing, Borrowers may make distributions pursuant to the terms herein. 

  

	9.7	SUBDIVISION MAPS. Prior to recording any final map, plat, parcel map, lot line adjustment or other subdivision map of any kind covering any portion of any Property (collectively, “Subdivision
Map”), Borrowers shall submit such Subdivision Map to Lender for Lender’s review and approval, which approval shall not be unreasonably withheld. Within ten (10) Business Days after Lender’s receipt of such Subdivision Map,
Lender shall provide Borrowers written notice if Lender disapproves of said Subdivision Map. Lender shall be deemed to have approved the Subdivision Map if such notice is not provided to Borrowers. Within five (5) Business Days after
Lender’s request, Borrowers shall execute, acknowledge and deliver to Lender such amendments to the Loan Documents as Lender may reasonably require to reflect the change in the legal description of such Property resulting from the recordation
of any Subdivision Map. In connection with and promptly after the recordation of any amendment or other modification to any Security Instrument recorded in connection with such amendments, Borrowers shall deliver to Lender, at Borrowers’ sole
expense, a title endorsement to the Title Policy in form and substance satisfactory to Lender insuring the continued first priority lien of such Security Instrument. Subject to the execution and delivery by Borrower of any documents required under
this Section, Lender shall, if required by applicable law, sign any Subdivision Map approved, or deemed to be approved, by Lender pursuant to this Section. For avoidance of doubt, Lender hereby approves the proposed lot line adjustment of the
Bluegrass Valley II Property. 

  

	9.8	 SECURITY DEPOSITS. Borrowers shall deposit into an account with and, to the extent permitted by Applicable Laws, controlled by Lender
(the “Security Deposit Account”) security deposits under Approved Leases. As additional security for Borrowers’ performance under the Loan Documents, to the extent permitted by law, each Borrower hereby irrevocably pledges and
assigns to Lender all monies at any time deposited in the Security Deposit Account, subject to tenant’s rights in and to the deposits under Approved Leases. Provided there is no Default by any Borrower in existence, Borrowers may withdraw funds
from the Security Deposit Account for application as permitted under the applicable Approved Lease and to cover any amounts which Borrowers certify in writing to Lender are recoverable from the applicable tenant’s security deposit.
Notwithstanding the foregoing, from time to time Lender may require an accounting from Borrowers of funds in the Security Deposit Account, and in the event that Borrowers’ accounting discloses a balance in the Security Deposit Account less than
the aggregate amount of security deposits collected (less any amounts legitimately applied in accordance with this Section 9.8), Borrowers shall promptly, but in any event within five (5) Business Days and prior to any further
withdrawals from the Security Deposit Account by Lender, fund additional monies into the Security Deposit Account such that no discrepancy remains. Upon satisfaction of the Loan in full, any tenant security deposits held by Lender shall be returned
to Borrowers. Upon a Partial Release, any tenant security deposits held by Lender with respect to the Property or Properties subject to the Partial Release shall be returned to Borrowers. In addition, following termination of

  

					
		 	37	  	Loan No. 1015003

	 	
any Approved Lease, provided a Default does not then exist, any tenant security deposits held by Lender with respect to such terminated Approved Lease may be withdrawn by Borrowers to the extent
that Borrowers are obligated to return same to tenant; provided, however, if a Default exists, Borrowers shall not have the right to withdraw such amounts directly, but may request a withdrawal of any tenant security deposits held by Lender with
respect to such terminated Approved Lease and Lender shall either (i) make such funds available to Borrowers for return to the applicable tenant or (ii) return such funds directly to the tenant. Each Borrower hereby represents to and for
the benefit of Lender that nothing contained in this Section 9.8 conflicts with the terms of any Approved Lease. 

  

	9.9	GOVERNMENTAL COMPLIANCE. Each Borrower shall comply (and shall cause its respective Property to comply) with all Applicable Laws other than de minimis non-compliance. 

 

	9.10	ASSIGNMENT. Without the prior written consent of Lender and except as otherwise provided with respect to Permitted Transfers, no Borrower shall assign such Borrower’s interest under any of the Loan
Documents, or in any monies due or to become due thereunder, and any assignment without such consent shall be void. In this regard, each Borrower acknowledges that Lender would not make this Loan except in reliance on Borrowers’ expertise,
reputation, prior experience in developing and constructing commercial real property, Lender’s knowledge of Borrowers, and Lender’s understanding that this Agreement is more in the nature of an agreement involving personal services than a
standard loan where Lender would rely on security which already exists. 

  

	9.11	MANAGEMENT AND LEASING OF PROPERTIES. Subject to the last sentence of this Section 9.11, without the prior written consent of Lender, no Borrower shall enter into any agreement providing for
the management, leasing or operation of any Property. Without the prior written consent of Lender, no Borrower shall terminate or materially amend the Management Agreement or any Listing Agreement required to be approved by Lender. Notwithstanding
the foregoing, a Borrower may enter into without the consent of Lender an agreement for the leasing of a Property if such agreement is terminable without cause, payment or penalty upon thirty (30) days or less notice and following the execution
of such agreement such Borrower shall not amend any such criteria. 

  

	9.12	SUBORDINATION OF MANAGEMENT AGREEMENT. Borrowers shall cause each Manager that enters into a Management Agreement to enter into a Management Agreement Subordination to subordinate such Management Agreement
to the Loan and collaterally assign such Management Agreement to Lender. Any such agreement shall provide that Lender may terminate the Management Agreement without payment of termination fees, liquated damages or penalty upon the occurrence of
(a) a Default or (b) a foreclosure of the applicable Security Instrument or the acceptance by Lender of a deed in lieu of foreclosure. 

  

	9.13	SUBORDINATION OF LISTING AGREEMENT. Borrowers shall cause each Listing Agent that enters into a Listing Agreement to enter into a Listing Agreement Subordination to subordinate such Listing Agreement to
the Loan and collaterally assign such Listing Agreement to Lender, unless such Listing Agreement is terminable without cause, payment or penalty upon thirty (30) days or less notice. Any such agreement shall provide that Lender may terminate
the Listing Agreement without payment of termination fees, liquated damages or penalty upon the occurrence of (a) a Default or (b) a foreclosure of the Security Instrument or the acceptance by Lender of a deed in lieu of foreclosure.

  

	9.14	 MANAGER. Each Borrower warrants, represents and agrees that it shall cause any Manager retained with respect to one or more Properties
to operate, administer, manage and lease such applicable Properties in a commercially first class manner. Each Borrower warrants and represents that any existing Manager or any future Manager has or will have expertise in operating, managing,
administering and leasing office building properties similar to the Property or Properties such Manager manages. In addition, each Borrower covenants and agrees that in no event shall such Borrower amend, modify, assign or terminate the terms and
provisions of any 

  

					
		 	38	  	Loan No. 1015003

	 	
Management Agreement (nor any of its rights thereunder) without the Lender’s prior written consent. Each Borrower covenants and agrees to promptly provide to Lender a copy of any such
amendment, modification, assignment or termination. 

  

	9.15	DEVELOPMENT OF PROPERTIES. Except for the Development Agreements, no Borrower shall enter into any agreement providing for the development of any Property without Lender’s prior written consent.
Without the prior written consent of Lender, Borrower shall not terminate or materially amend any Development Agreement or any development agreement approved by Lender. 

 

	9.16	SWAP AGREEMENTS. If any Borrower enters into any Swap Agreement with Lender, such Borrower shall, upon receipt from Lender, execute promptly all documents evidencing such transaction. If at any time any
Borrower enters into a Swap Agreement in connection with the Loan, then such Borrower shall assign its rights to payment under such Swap Agreement to Lender as additional security for the Loan pursuant to a collateral assignment of interest rate
protection agreement in form and content reasonably acceptable to Lender. 

  

	9.17	SUBORDINATION OF DEVELOPMENT AGREEMENT. Borrowers shall cause each Developer that enters into a Development Agreement with respect to the Bluegrass Valley II Property or the Lehigh Valley II Property or
any new Development Agreement with respect to a Property or Properties after the Effective Date to enter into a Development Agreement Subordination to subordinate such Development Agreement to the Loan and collaterally assign such Development
Agreement to Lender. Any such agreement shall provide that Lender may terminate the Development Agreement without payment of termination fees, liquated damages or penalty upon the occurrence of (a) a Default or (b) a foreclosure of the
applicable Security Instrument or the acceptance by Lender of a deed in lieu of foreclosure. 

  

	9.18	PROPERTY TRANSFERS. 

  

	 	(a)	Prohibited Property Transfers. Borrower shall not cause or permit any Transfer of all or any part of any Property (collectively, a “Prohibited Property Transfer”), including, without
limitation, (i) a lease of all or a material part of any Property for any purpose other than actual occupancy by a space tenant; and (ii) the Transfer of all or any part of a Borrower’s right, title and interest in and to any Lease or
Lease payments. 

  

	 	(b)	Permitted Property Transfers. Notwithstanding the foregoing, none of the following Transfers shall be deemed to be a Prohibited Property Transfer: (i) a Permitted Transfer or other Transfer, which is
expressly permitted under this Agreement (including pursuant to Section 2.12 above); (ii) a Lease which is permitted under the terms of the Loan Documents; (iii) the sale of inventory in the ordinary course of business.

  

	9.19	EQUITY TRANSFERS. 

  

	 	(a)	 Prohibited Equity Transfers. Borrower shall not cause or permit any Transfer of any direct or indirect legal or beneficial interest in a
Restricted Party (collectively, a “Prohibited Equity Transfer”), including without limitation, (i) if a Restricted Party is a corporation, any merger, consolidation or other Transfer of such corporation’s stock or the
creation or issuance of new stock in one or a series of transactions; (ii) if a Restricted Party is a limited partnership, limited liability partnership, general partnership or joint venture, any merger or consolidation or the change, removal,
resignation or addition of a general partner, managing member or non-member manager or the Transfer of the partnership interest of any general or limited partner or any profits or proceeds relating to such
partnership interests or the creation or issuance of new limited partnership interests; (iii) if a Restricted Party is a limited liability company, any merger or consolidation or the change, removal, resignation or addition of a managing member
or non-member manager (or if no managing member, any member) or any profits or proceeds relating to 

  

					
		 	39	  	Loan No. 1015003

	 	
such membership interest, or the Transfer of a non-managing membership interest or the creation or issuance of new non-managing membership interests; or (iv) if a Restricted Party is a
trust, any merger, consolidation or other Transfer of any legal or beneficial interest in such Restricted Party or the creation or issuance of new legal or beneficial interests. 

 

	 	(b)	Permitted Equity Transfers. Notwithstanding the foregoing or any other provision hereunder to the contrary, the following equity transfers shall be permitted and shall not be deemed Prohibited Equity
Transfers (and each shall be permitted hereunder without the consent of Lender or the payment of any assumption fee), provided, (x) any of the applicable conditions set forth in this Section 9.19(b) are complied with by Borrower,
and (y) Borrower pays all of Lender’s reasonable out of pocket costs and expenses, including, without limitation, all reasonable attorneys’ fees, in connection therewith. 

 

	 	(1)	any direct or indirect transfer of any membership interest in Holdco to IPT or an Affiliate thereof; 

  

	 	(2)	upon the consummation of the Spin-Off, any direct transfer of any membership interest in Holdco to the Trust; or 

  

	 	(3)	any transfer occurring by inheritance, devise, bequest, will, intestate succession or by operation of law upon the death of a natural person who is a beneficiary of the Trust; provided that a beneficiary of the Trust
shall be allowed to assign or transfer a beneficial interest held by a tax-qualified employee retirement plan or account (including a regular IRA, a Keogh plan or a 401(k) plan) to the plan participant or account owner, but only if and to the extent
that (x) a distribution from the plan or account is required to be made in order to satisfy the required minimum distribution (“RMD”) provisions applicable to such plan or account, and (y) such RMD requirements cannot be
satisfied by distributing other assets from such plan or account, or from other accounts of such account owner; and further provided, that the executor or administrator of the estate of a beneficiary may mortgage, pledge, grant a security interest
in, hypothecate or otherwise encumber, the beneficial interest held by the estate of such beneficiary if necessary in order to borrower money to pay estate, succession or inheritance taxes or the expenses of administering the estate of the
beneficiary. 

  

	 	(c)	SPE Status. Nothing contained in this Section shall be construed to permit any Transfer which would result in a breach of any representation, warranty or covenant of any Borrower under Article 7.

  

	9.20	CERTIFICATES OF OWNERSHIP. Borrowers shall deliver to Lender, at any time and from time to time (provided there is no Default, no more than once in a twelve (12) month period), not more than five
(5) days after Lender’s written request therefor, a certificate, in form acceptable to Lender, signed and dated by each Borrower, listing the names of all Persons holding direct or indirect legal or beneficial interests in the Property and
Improvements or any Restricted Party and the type and amount of each such interest; provided, however, such certificate shall not be required to list the names of any limited partners, non-managing members or beneficiaries of the
Trust. 

  

	9.21	ACCOUNTS AND CASH FLOW. 

  

	 	(a)	Each Borrower shall, simultaneously herewith, establish an Operating Account, into which the respective Borrower shall deposit all revenues, income, sales proceeds, insurance proceeds, rents, refunds, reimbursements or
other amounts or proceeds of any kind whatsoever generated by the Properties. 

  

					
		 	40	  	Loan No. 1015003

	 	(b)	Until deposited into the Operating Account, any Gross Operating Income and other revenue from the Properties held by Borrowers, which are received by or on behalf of or credited to Borrowers after the date hereof, shall
be deemed to be collateral and shall be held in trust by it for the benefit, and as the property, of Lender pursuant to the Security Instruments and shall not be commingled with any other funds or property of Borrowers. 

 

	 	(c)	Provided no Default exists, amounts deposited into the Operating Account may be transferred at the discretion of Borrower to the Master Operating Account each Business Day. 

 

	 	(d)	During the existence of a Default, all Gross Operating Income shall be deposited directly into the Lockbox Account in accordance with the Borrowers Cash Management Agreement and the Guarantor Cash Management Agreement.

  

	 	(e)	Borrowers shall at all times remain responsible to pay debt and operating expenses of each Property, whether or not there are sufficient funds in the Master Operating Account or any Operating Account to pay such costs
and expenses. 

  

	9.22	ADDITIONAL DEBT AND SEPARATE GUARANTY. Without the prior written consent of Lender, no Borrower shall: 

  

	 	(a)	incur, create or assume any indebtedness or liabilities, other than: 

  

	 	(i)	the Loan; 

  

	 	(ii)	any Swap Agreement entered into in accordance with the terms of this Agreement; and 

  

	 	(iii)	any Permitted Debt; or 

  

	 	(b)	directly or indirectly guaranty the obligations of any other person or entity, or become obligated for the debts of any other person or entity, or hold out its credit as being available to pay the obligations of any
other person or entity. 

 No debt other than the Loan or any Swap Agreement between Borrowers and Lender may be secured by any
Property or any direct or indirect interest in Borrower, whether senior, subordinate or pari passu. 
  

	9.23	EXISTENCE. Each Borrower shall preserve and maintain its existence; conduct its business in an orderly, efficient, and regular manner; and comply in all materials respects with the requirements of all
applicable laws, rules, regulations and orders of a governmental authority. 

  

	9.24	TAXES AND OTHER LIABILITIES. Each Borrower shall pay and discharge when due any and all indebtedness, obligations, assessments and taxes, both real and personal, owed by or relating to such Borrower and
such Borrower’s properties (including federal and state income taxes), except as such Borrower may in good faith contest or as to which a bona fide dispute may arise, provided provision is made to the satisfaction of Lender for eventual payment
thereof in the event that it is found that the same is an obligation of such Borrower. 

  

	9.25	 NOTICE. Upon any Borrower’s receipt of notice or obtaining actual knowledge thereof, Borrowers shall promptly give notice in
writing to Lender of: (a) any material litigation pending or threatened in writing against Borrower (that would not, in either case, be covered in all material respects by Borrowers’ insurance policies); (b) the occurrence of any
breach or uncured default in the payment or performance of any material obligation owing by any Borrower to any person or entity, other than Lender; (c) any change in the name of any Borrower and any change in its

  

					
		 	41	  	Loan No. 1015003

	 	
identity or organizational structure; (d) any uninsured or partially uninsured loss through fire, theft, liability damage; or (e) any termination or cancellation of any insurance policy
which any Borrower is required herein to maintain. 

  

	9.26	ACTIONS TO MAINTAIN PROPERTY. Borrowers shall: 

  

	 	(a)	Keep each Property in good repair and condition. Borrowers shall make, or cause to be made, any repairs, renewals and replacements, renovations or capital improvements to each Property in a good and workmanlike manner,
free of defects and liens, substantially in accordance with the applicable plans and specifications and in compliance will all applicable laws, regulations and requirements; 

 

	 	(b)	Not initiate or acquiesce to a zoning change of any Property without prior notice to, and prior written consent from, Lender; 

  

	 	(c)	Not allow material changes in the stated use of any Property from that disclosed to Lender at the time of execution hereof without prior notice to, and prior written consent from, Lender; and 

 

	 	(d)	Comply with all governmental requirements and the applicable Plans and Specifications in all material respects with respect to the development of the Construction Properties and construction of the Construction
Improvements. 

  

	9.27	MATERIAL CONTRACTS. Except as expressly required under this Agreement, Borrowers shall not do any of the following without the Lender’s prior written consent (not to be unreasonably withheld):
(i) enter into any Material Contract; (ii) reduce or extend the term of, increase the charges or fees payable by such party under, decrease the charges or fees payable to such party under, or otherwise modify or amend in any respect, any
Material Contract; (iii) surrender, modify, restate or otherwise amend in any material respect, or terminate, any Material Contract; or (iv) breach any provision of any Material Contract. Borrowers shall promptly deliver to Lender copies
of any material notices or default notices given to Borrowers pursuant to any Material Contract. 

  

	9.28	INSURANCE. Borrowers shall maintain and keep in force the insurance policies and coverages contemplated by and in accordance with Article 5 above. 

 

	9.29	FURTHER ASSURANCES. Upon Lender’s request and at Borrowers’ sole cost and expense, Borrowers shall, and shall cause any Affiliate party thereto, if any, to execute, acknowledge and deliver any
other instruments, including replacement promissory notes, guaranties and other loan documents, and perform any other acts necessary, desirable or proper, as reasonably determined by Lender, to correct clerical errors or omissions in any loan
closing documentation, to replace any lost or destroyed loan closing documentation, or to carry out the purposes of this Agreement and the other Loan Documents or to perfect and preserve any liens created by the Loan Documents. This obligation shall
survive any foreclosure or deed in lieu of foreclosure of any Property. 

 ARTICLE 10. REPORTING COVENANTS 

 

	10.1	FINANCIAL INFORMATION. Within ninety (90) days after each Borrower’s and Guarantor’s fiscal year end, each such Borrower and Guarantor shall deliver to Lender (a) financial statements
reasonably acceptable in form to Lender (including a statement of net assets and changes in net assets in accordance with the Liquidation Basis Accounting (GAAP) consistently applied, together with supporting property and mortgage debt schedules,
for the Borrowers and Guarantor; (b) a yearly business plan and (c) if required by Lender, financial and/or cash flow projections for the ensuing twelve (12) months. 

  

					
		 	42	  	Loan No. 1015003

	10.2	TAX RETURNS. If required by Lender, Borrowers shall deliver to Lender within fifteen days of filing or on October 31st of each year, whichever is earlier, complete copies of federal and state tax
returns for each Borrower and Guarantor, together with all applicable schedules thereto, each of which shall be signed and certified by an authorized officer of the each Borrower and Guarantor, as applicable, to be true and complete copies of such
returns. In the event an extension is filed, a copy of the extension shall be delivered to Lender within thirty (30) days from filing. 

  

	10.3	BOOKS AND RECORDS. Borrowers shall maintain complete books of account and other records for the Properties and for disbursement and use of the proceeds of the Loan and Borrowers’ Funds, and the same
shall be available for inspection and copying by Lender upon reasonable prior notice. 

  

	10.4	REPORTS. Within ten (10) Business Days of Lender’s request, Borrowers shall deliver to Lender other information reasonably requested by Lender, all in form and substance acceptable to Lender,
with respect to the Properties. 

  

	10.5	LEASING REPORTS. Borrowers shall deliver to Lender, within twenty (20) days after each fiscal quarter end, leasing status reports, and rent rolls with respect to each Property, each in form and
substance satisfactory to Lender. 

  

	10.6	OPERATING STATEMENTS FOR PROPERTIES. Until such time as the Note is paid in full, each Borrower shall deliver to Lender within twenty (20) days after each calendar quarter end (other than year end
statements, which shall be provided within sixty (60) days of year end), an “operating statement” for each Property in form and substance reasonably acceptable to Lender. 

 

	10.7	PROJECTED FINANCIAL STATEMENTS AND OTHER INFORMATION. Prior to any calculation of any Outstanding Amount Debt Yield, Borrowers shall deliver to Lender such projections, proforma financial statements, rent
roll and other information requested by Lender required to make such determinations no later than ten (10) Business Days prior to the applicable Determination Date. 

ARTICLE 11. DEFAULTS AND REMEDIES 
  

	11.1	DEFAULT. The occurrence of any one or more of the following shall constitute an event of default (“Default”) under this Agreement and the other Loan Documents: 

 

	 	(a)	Monetary. Borrowers’ failure to pay (i) any principal or interest payments under the Note when due, (ii) any other sums required by any of the Loan Documents to be paid on the Maturity Date,
or (iii) any other sums payable under any of the Loan Documents when due, and such failure continues for ten (10) days after written notice from Lender to Borrowers of such failure; or 

 

	 	(b)	Performance of Obligations. Any Borrower’s failure to perform any obligation in addition to those in Section 11.1(a) above under any of the Loan Documents, and the continuation of such
failure for forty-five (45) days after written notice thereof from Lender to Borrowers; provided, however, that if a different cure period is provided herein or in any of the other Loan Documents for the remedy of such failure,
such Borrower’s failure to perform will not constitute a Default until such date as the specified cure period expires; provided, however, if such failure cannot be cured or remedied with such forty-five (45) day period or
other applicable period, but such Borrower has commenced the cure or remedy of such failure within such applicable period and thereafter diligently and continuously prosecutes such cure or remedy, then such Borrower shall be entitled to a reasonable
period of time (not to exceed one hundred twenty (120) days) to cure or remedy such failure; or 

  

					
		 	43	  	Loan No. 1015003

	 	(c)	Construction; Use. (i) There is any material deviation in the work of construction from the Plans and Specifications or governmental requirements or the appearance or use of defective workmanship or
materials in constructing each Construction Improvements project, and Borrower fails to remedy the same to Lender’s satisfaction within twenty (20) days of Lender’s written demand to do so; provided, however, if such
cure cannot be cured or remedied within such twenty (20) day period, but Borrower has commenced the cure or remedy of such failure within such applicable period, and thereafter diligently and continuously prosecutes such cure or remedy, then
Borrowers shall be entitled to a reasonable period of time (not to exceed sixty (60) days) to cure or remedy such failure; or (ii) there is a cessation of construction of the Improvements prior to completion for a continuous period of more
than twenty (20) days (except as caused by an event of force majeure for which a longer delay may be permitted under Article 4); or (iii) the construction of the Improvements, or the sale or leasing of any of the Improvements
in accordance with the Loan Documents is prohibited, enjoined or delayed for a continuous period of more than thirty (30) days; or (iv) utilities or other public services necessary for the full occupancy and utilization of the Property and
Improvements are curtailed for a continuous period of more than thirty (30) days; or 

  

	 	(d)	Liens, Attachment; Condemnation. (i) The recording of any lien affidavit against any Property or the giving to any Borrower of any notice of unpaid claims for work, material or specially fabricated
items or of a contractual retainage claim relating to any Property and the continuance of such lien claim or notice unless Borrowers shall have, within thirty (30) days after such recordation or notice thereof or five (5) days after
Lender’s demand therefor, whichever first occurs, either (A) contests same in a manner and with such assurances thereof that are reasonably acceptable to Lender, (B) discharges, releases or satisfies same, (C) provides for
payment thereof in a manner satisfactory to Lender, or (ii) the condemnation, seizure or appropriation of, or occurrence of an uninsured casualty (except if Borrowers are able to restore same at its sole expense and for which such funds have
been deposited into the Guarantor Reserve Account) with respect to any material portion of such Property; or (iii) the sequestration or attachment of, or any levy or execution upon any of the Property or Improvements, any other collateral
provided by a Borrower under any of the Loan Documents, any monies in the Account, or any substantial portion of the other assets of any Borrower, which sequestration, attachment, levy or execution is not released, expunged or dismissed prior to the
earlier of thirty (30) days or the sale of the assets affected thereby; or 

  

	 	(e)	Representations and Warranties. Any representation, warranty, certificate or other written statement (financial or otherwise) made or furnished by or, in the case of any financial statements of a Borrower
or Guarantor, on behalf of a Borrower or Guarantor, to Lender under or in connection with any of the Loan Documents shall be false, incorrect, incomplete or misleading in any material respect when made or furnished; or 

 

	 	(f)	Voluntary Bankruptcy; Insolvency; Dissolution. (i) The filing of a petition by any Borrower or Guarantor for relief under the Bankruptcy Code, or under any other present or future state or federal law
regarding bankruptcy, reorganization or other debtor relief law; (ii) the filing of any pleading or an answer by any Borrower or Guarantor in any involuntary proceeding under the Bankruptcy Code or other debtor relief law which admits the
jurisdiction of the court or the petition’s material allegations regarding such Borrower’s or Guarantor’s insolvency; (iii) a general assignment by any Borrower or Guarantor for the benefit of creditors; or
(iv) any Borrower or Guarantor applying for, or the appointment of, a receiver, trustee, custodian or liquidator of Borrower or any of its property which receiver, trustee, custodian or liquidator is not discharged within ninety
(90) days after the appointment; or 

  

	 	(g)	 Involuntary Bankruptcy. The failure of any Borrower or Guarantor to effect a full dismissal of any involuntary petition under the
Bankruptcy Code or under any other 

  

					
		 	44	  	Loan No. 1015003

	 	
debtor relief law that is filed against such Borrower or Guarantor in any way restrains or limits such Borrower, Guarantor or Lender regarding the Loan, any Property, prior to the earlier of the
entry of any court order granting relief sought in such involuntary petition, or ninety (90) days after the date of filing of such involuntary petition; or 

  

	 	(h)	General Partners of Borrower, Guarantor and Indemnitor. The occurrence of any of the events specified in Sections 11.1(f) or 11.1(g) as to any general partner of Borrower, Guarantor or
Indemnitor; or 

  

	 	(i)	Change In Management or Control. 

  

	 	(i)	Except for any Permitted Transfer, the occurrence of any material management or organizational change in any Borrower or in the managing member of any Borrower, including, without limitation, any partnership, joint
venture, manager or member dispute which would reasonably be expected to have a Material Adverse Effect; 

  

	 	(ii)	Following the occurrence of the Spin-Off, the Trust shall cease to be the managing member of Guarantor; 

  

	 	(iii)	Except for any Permitted Transfer, any Person other than Holdco, is or becomes the owner, directly or indirectly, of more than 10.0% of the total voting power of the then outstanding voting stock of the Trust; or

  

	 	(iv)	During any twelve (12) month period, individuals who at the beginning of such period constituted the board of trustees of the Trust (the “Board”) (together with any new trustee whose election by
the Board or whose nomination for election by the shareholders of Trust was approved by a vote of at least a majority of the trustees of the Board then in office who either were trustees of the Board at the beginning of such period or whose election
or nomination for election was previously so approved) cease for any reason (other than death or disability) to constitute a majority of the trustees of the Board then in office. 

 

	 	(j)	Loss of Priority. The failure at any time of any Security Instrument to be a valid lien upon a Property or any portion thereof, other than as a result of any release or reconveyance of such Security
Instrument with respect to all or any portion of such Property pursuant to the terms and conditions of this Agreement, prior and superior to all other liens and encumbrances thereon except those approved by Lender in writing; or 

 

	 	(k)	Hazardous Materials. The discovery of any significant Hazardous Materials in, on or about any Property subsequent to the Effective Date. Any such Hazardous Materials shall be “significant” for
this purpose if said Hazardous Materials, in Lender’s reasonable discretion, have a materially adverse impact on the value of such Property; or 

  

	 	(l)	Transfer. If a Transfer, other than a Permitted Transfer, occurs without Lender’s prior written approval; or 

  

	 	(m)	Transfer of Assets. The sale, assignment, pledge, hypothecation, mortgage or transfer of assets of any Borrower or Guarantor other than in the ordinary course of business of said entity or in connection
with a Permitted Transfer; or 

  

	 	(n)	Default Under Unsecured Hazardous Materials Indemnity Agreement. The occurrence and continuance of a default (subject to any cure or grace period applicable thereto) under that certain Hazardous Materials
Indemnity Agreement (Unsecured) executed by Indemnitor in connection with the Loan, in favor of Lender, and dated of even date herewith, including without limitation, Indemnitor’s failure to perform any covenant, condition or obligation
thereunder; or 

  

					
		 	45	  	Loan No. 1015003

	 	(o)	Default Under Guaranty. The occurrence and continuance of a default (subject to any cure or grace period applicable thereto) under any guaranty now or hereafter executed in connection with the Loan,
including without limitation, Guarantor’s failure to perform any covenant, condition or obligation thereunder; or 

  

	 	(p)	Default Under Swap Agreement. An “Event of Default” (subject to any cure or grace period applicable thereto) occurs under any Swap Agreement (as defined therein) between any Borrower and Lender;
or 

  

	 	(q)	Violation of Separate Purpose Entity Provisions. The occurrence and continuance of any default in the observance of the Separateness Provisions applicable to Borrowers which Lender, in its reasonable
judgment, determines would reasonably be expected to cause a substantive consolidation of any Borrower in a bankruptcy proceeding; or 

  

	 	(r)	Breach of Sanctions Provision. The failure of any representation or warranty of any Borrower, or any Borrower’s failure to perform or observe any covenant, contained in Section 6.23.

  

	11.2	ACCELERATION UPON DEFAULT; REMEDIES. Upon the occurrence of any Default specified in this Article 11, Lender may, at its sole option, declare all sums owing to Lender under the Note, this
Agreement and the other Loan Documents immediately due and payable after which such sums shall, at Lender’s option, bear interest at the Default Rate (as defined in the Note), provided, however, that all sums owing to Lender under
the Note, this Agreement and the other Loan Documents shall automatically become immediately due and payable upon the occurrence of any of the Defaults listed in Sections 11.1(f), 11.1(g) and 11.1(h), after which such sums shall
bear interest at the Default Rate (as defined in the Note). Upon any such acceleration, (i) Lender may, in addition to all other remedies permitted under the Note, this Agreement and the other Loan Documents and at law or equity, apply any and
all sums in the Account to the sums owing under the Loan Documents; and (ii) and any and all obligations of Lender to fund further disbursements under the Loan shall terminate at Lender’s sole option. 

 

	11.3	DISBURSEMENTS TO THIRD PARTIES. Upon the occurrence of a Default occasioned by Borrower’s failure to pay money to a third party as required by this Agreement, Lender may but shall not be obligated to
make such payment from the Loan proceeds, Borrowers’ Funds, other funds of Lender or any amounts in deposit accounts maintained by Borrower with Lender. If such payment is made from proceeds of the Loan or from Borrowers’ Funds, Borrowers
shall immediately deposit with Lender, upon written demand, an amount equal to such payment. If such payment is made from funds of Lender, Borrowers shall immediately repay such funds upon written demand of Lender. In either case, the Default with
respect to which any such payment has been made by Lender shall not be deemed cured until such deposit or repayment (as the case may be) has been made by Borrower to Lender. 

 

	11.4	LENDER’S COMPLETION OF CONSTRUCTION. Upon the occurrence of a Default, Lender may, upon five (5) days prior written notice to Borrowers, and with or without legal process, take possession of the
Construction Properties, remove Borrowers and all agents, employees and contractors of Borrower from the Construction Properties, complete the work of construction and market, operate and sell or lease the Construction Properties. For this purpose,
each Borrower irrevocably appoints Lender as its attorney-in-fact, which agency is coupled with an interest. As attorney-in-fact, Lender may, in each Borrower’s name, take or omit to take any action Lender may deem appropriate, including, without limitation, exercising Borrowers’ rights under the Loan
Documents and all contracts concerning the Properties. 

  

					
		 	46	  	Loan No. 1015003

	11.5	LENDER’S RIGHT TO STOP CONSTRUCTION. If Lender determines at any time that the Construction Improvements are not being constructed in accordance with the Plans and Specifications and all governmental
requirements, Lender may immediately cause all construction to cease on any of the Construction Improvements affected by the condition of nonconformance and withhold further disbursements under the Loan. Borrowers shall thereafter not allow any
construction work, other than corrective work, to be performed on any of the Construction Improvements affected by the condition of nonconformance until such time as Lender notifies Borrowers in writing that the nonconforming condition has been
corrected. Borrowers shall notify Lender and Lender’s inspector immediately upon receipt of “red tag” or “stop order” notices from any federal, state, county or municipal building inspector or of unsatisfactory compliance
with any applicable building code, and in such event Borrowers shall provide Lender and Lender’s inspector with a full and complete written explanation of the nature of such noncompliance. 

 

	11.6	SET OFF. Upon the occurrence of a Default, Lender may set off any and all amounts due by any Borrower against any indebtedness or obligation of Lender to Borrower. 

 

	11.7	RIGHTS CUMULATIVE, NO WAIVER. All of Lender’s rights and remedies provided in this Agreement, the other Loan Documents and the Other Related Documents, together with those granted by law or at equity,
are cumulative and may be exercised by Lender at any time. Lender’s exercise of any right or remedy shall not constitute a cure of any Default unless all sums then due and payable to Lender under the Loan Documents are repaid and Borrowers have
cured all other Defaults. No waiver shall be implied from any failure of Lender to take, or any delay by Lender in taking, action concerning any Default or failure of condition under the Loan Documents, or from any previous waiver of any similar or
unrelated Default or failure of condition. Any waiver or approval under any of the Loan Documents must be in writing and shall be limited to its specific terms. 

ARTICLE 12. MISCELLANEOUS PROVISIONS 
  

	12.1	INDEMNITY. EACH BORROWER HEREBY AGREES TO DEFEND, INDEMNIFY AND HOLD HARMLESS INDEMNITEES FOR, FROM AND AGAINST ANY AND ALL LOSSES, DAMAGES, LIABILITIES, CLAIMS, ACTIONS, JUDGMENTS, COURT COSTS AND
LEGAL OR OTHER EXPENSES (INCLUDING, WITHOUT LIMITATION, REASONABLE ATTORNEYS’ FEES AND EXPENSES) WHICH ANY INDEMNITEE MAY INCUR AS A DIRECT OR INDIRECT CONSEQUENCE OF: (a) THE PURPOSE TO WHICH BORROWERS APPLY THE LOAN PROCEEDS;
(b) THE FAILURE OF ANY BORROWER TO PERFORM ANY OBLIGATIONS AS AND WHEN REQUIRED BY THIS AGREEMENT OR ANY OF THE OTHER LOAN DOCUMENTS; (c) ANY FAILURE AT ANY TIME OF ANY OF BORROWERS’ REPRESENTATIONS OR WARRANTIES TO BE TRUE AND
CORRECT; OR (d) ANY ACT OR OMISSION BY ANY BORROWER, CONSTITUENT ENTITIES OF SUCH BORROWER, ANY CONTRACTOR, SUBCONTRACTOR OR MATERIAL SUPPLIER, ENGINEER, ARCHITECT OR OTHER PERSON OR ENTITY WITH RESPECT TO ANY OF THE PROPERTIES; PROVIDED THAT
SUCH INDEMNITY SHALL NOT, AS TO ANY INDEMNITEE, BE AVAILABLE TO THE EXTENT THAT SUCH LOSSES, DAMAGES, LIABILITIES, CLAIMS, ACTIONS, JUDGMENTS, COURT COSTS, OR LEGAL OR OTHER EXPENSES ARE DETERMINED BY A COURT OF COMPETENT JURISDICTION BY FINAL AND
NONAPPEALABLE JUDGMENT TO HAVE RESULTED FROM THE GROSS NEGLIGENCE OR WILLFUL MISCONDUCT OF SUCH INDEMNITEE. BORROWERS SHALL IMMEDIATELY PAY TO INDEMNITEES UPON DEMAND ANY AMOUNTS OWING UNDER THIS INDEMNITY, TOGETHER WITH INTEREST FROM THE DATE THE
INDEBTEDNESS ARISES UNTIL PAID AT THE RATE OF INTEREST APPLICABLE TO THE PRINCIPAL BALANCE OF THE NOTE. EACH BORROWER’S DUTY AND OBLIGATIONS TO DEFEND, INDEMNIFY AND HOLD HARMLESS ANY INDEMNITEE SHALL SURVIVE CANCELLATION OF THE NOTE AND THE
RECONVEYANCE, RELEASE OR PARTIAL RECONVEYANCE, RELEASE OR SATISFACTION OF THE SECURITY INSTRUMENTS. THE INDEMNITY OBLIGATIONS OF BORROWERS UNDER THE LOAN DOCUMENTS SHALL ALSO APPLY WITH RESPECT TO ANY PARTICIPANT AS DEFINED AND PROVIDED FOR IN
SECTION 12.13. 

  

					
		 	47	  	Loan No. 1015003

	12.2	FORM OF DOCUMENTS. The form and substance of all documents, instruments, and forms of evidence to be delivered to Lender under the terms of this Agreement and any of the other Loan Documents shall be
subject to Lender’s approval and shall not be modified, superseded or terminated in any respect without Lender’s prior written approval. 

  

	12.3	NO THIRD PARTIES BENEFITED. No person other than Lender and Borrowers and their permitted successors and assigns shall have any right of action under any of the Loan Documents. 

 

	12.4	NOTICES. All notices, demands, or other communications under this Agreement and the other Loan Documents shall be in writing and shall be delivered to the appropriate party at the address set forth below
(subject to change from time to time by written notice to all other parties to this Agreement). All notices, demands or other communications shall be considered as properly given if delivered personally or sent by first class United States Postal
Service mail, postage prepaid, by certified mail, return receipt requested, by Overnight Express Mail or by overnight commercial courier service, charges prepaid, except that notices of Default may be sent by certified mail, return receipt
requested, charges prepaid. Notices so sent shall be effective three (3) Business Days after mailing, if mailed by first class mail, and otherwise upon delivery or refusal; provided, however, that non-receipt of any communication
as the result of any change of address of which the sending party was not notified or as the result of a refusal to accept delivery shall be deemed receipt of such communication. For purposes of notice, the address of the parties shall be:

  

					
		 	Borrower:	 	c/o DC Liquidating Assets Holdco LLC
		 		 	518 17th Street, 17th Floor
		 		 	Denver, CO 80202
		 		 	Attn: Lainie Minnick, Senior Vice President
			
		 	With a copy to:	 	c/o DC Liquidating Assets Holdco LLC
		 		 	518 17th Street, 17th Floor
		 		 	Denver, CO 80202
		 		 	Attn: Joshua J. Widoff, General Counsel
			
		 	Lender:	 	Wells Fargo Bank, National Association
		 		 	Commercial Real Estate/ REIT Finance Group (AU#2754)
		 		 	10 S. Wacker Drive, 32nd Floor
		 		 	Chicago, Illinois 60606
		 		 	Attn: Craig V. Koshkarian, Vice President
		 		 	Loan No. 1015003
			
		 	With a copy to:	 	Wells Fargo Bank, National Association
		 		 	Commercial Real Estate/ REIT Finance Group (AU#2754)
		 		 	1800 Century Park East, Suite 1200
		 		 	Los Angeles, California 90067
		 		 	Attn: Kevin A. Stacker, Senior Vice President
		 		 	Loan No. 1015003
			
		 	 and to:
	 	Wells Fargo Bank, National Association
		 		 	Commercial Real Estate/ REIT Finance Group (AU#2754)
		 		 	1800 Century Park East, Suite 1200
		 		 	Los Angeles, California 90067
		 		 	Attn: Ryan S. Gawel, Vice President
		 		 	Loan No. 1015003

  

					
		 	48	  	Loan No. 1015003

					
		 	 and to:
	 	Wells Fargo Bank, National Association
		 		 	Loan Center
		 		 	608 2nd Ave S
		 		 	Minneapolis, Minnesota 55402
		 		 	Attn: Breanna Schmid, Loan Servicing Specialist
		 		 	Loan No. 1015003

 Any party shall have the right to change its address for notice hereunder to any other location within the
continental United States by the giving of ten (10) days’ notice to the other party in the manner set forth hereinabove. 
  

	12.5	ATTORNEY-IN-FACT. Each Borrower hereby irrevocably appoints and authorizes Lender as such Borrower’s attorney-in-fact, to become effective only upon the occurrence and continuance of a Default, which
agency is coupled with an interest, and as such attorney-in-fact Lender may, without the obligation to do so, execute and/or record in Lender’s or such Borrower’s name any notices, instruments or documents that Lender deems appropriate to
protect Lender’s interest under any of the Loan Documents. 

  

	12.6	ACTIONS. Each Borrower agrees that Lender, in exercising the rights, duties or liabilities of Lender or such Borrower under the Loan Documents, may commence, appear in or defend any action or proceeding
purporting to affect any Property or the Loan Documents and Borrower shall immediately reimburse Lender upon demand for all such expenses so incurred or paid by Lender, including, without limitation, reasonable attorneys’ fees and expenses and
court costs. 

  

	12.7	RIGHT OF CONTEST. Borrowers may contest in good faith any claim, demand, levy or assessment (other than mechanic’s and materialmen’s lien claims which must be handled as specified in
Section 4.9) by any person other than Lender which would constitute a Default if: (a) Borrowers pursue the contest diligently, in a manner which Lender determines is not prejudicial to Lender, and does not impair the rights of
Lender under any of the Loan Documents; and (b) Borrowers deposit with Lender any funds or other forms of assurance which Lender in good faith determines from time to time appropriate to protect Lender from the consequences of the contest being
unsuccessful. Borrowers’ compliance with this Section shall operate to prevent such claim, demand, levy or assessment from becoming a Default. 

  

	12.8	RELATIONSHIP OF PARTIES. The relationship of Borrowers and Lender under the Loan Documents is, and shall at all times remain, solely that of borrower and lender, and Lender neither undertakes nor assumes
any responsibility or duty to Borrowers or to any third party with respect to the Properties, except as expressly provided in this Agreement and the other Loan Documents. 

 

	12.9	DELAY OUTSIDE LENDER’S CONTROL. Lender shall not be liable in any way to any Borrower or any third party for Lender’s failure to perform or delay in performing under the Loan Documents (and
Lender may suspend or terminate all or any portion of Lender’s obligations under the Loan Documents) if such failure to perform or delay in performing results directly or indirectly from, or is based upon, the action, inaction, or purported
action, of any governmental or local authority, or because of war, rebellion, insurrection, strike, lock-out, boycott or blockade (whether presently in effect, announced or in the sole judgment of Lender deemed probable), or from any Act of God or
other cause or event beyond Lender’s control. 

  

	12.10	 ATTORNEYS’ FEES AND EXPENSES; ENFORCEMENT. If any attorney is engaged by Lender to enforce or defend any provision of this
Agreement, any of the other Loan Documents or Other Related Documents, or as a consequence of any Default under the Loan Documents, with or without the filing of any legal action or proceeding, and including, without limitation, any fees and
expenses incurred in any bankruptcy proceeding or in connection with any appeal of a lower court decision, then Borrowers shall immediately pay to Lender, upon demand, the amount of all

  

					
		 	49	  	Loan No. 1015003

	 	
reasonable attorneys’ fees and expenses and all costs incurred by Lender in connection therewith, including all trial and appellate proceedings in any legal action, suit, bankruptcy or other
proceeding, together with interest thereon from the date of such demand until paid at the rate of interest applicable to the principal balance of the Note as specified therein. In the event of any legal proceedings, court costs and attorneys’
fees shall be set by the court and not by any jury, and shall be included in any judgment obtained by Lender. 

  

	12.11	IMMEDIATELY AVAILABLE FUNDS. Unless otherwise expressly provided for in this Agreement, all amounts payable by Borrowers to Lender shall be (a) payable only in United States currency in immediately
available funds; and (b) received by Lender at the Loan Center address specified in the Note, or at other such places as may be designated in writing by Lender, no later than 2:30 PM Eastern Time. Any amounts received after such time may not be
credited until the next Business Day. 

  

	12.12	LENDER’S CONSENT. Wherever in this Agreement there is a requirement for Lender’s consent or approval and/or a document to be provided or an action or party to be acceptable or a document or
agreement to be in form and substance “satisfactory” to the Lender or an action is required by Lender or an action taken “to the satisfaction of Lender” or words or phrases of similar import, it is understood by such phrase that
Lender shall exercise its consent, right or judgment in a reasonable manner (unless another standard is expressly provided) given the specific facts and circumstance applicable at the time. If Lender’s consent or approval is required under
Sections 4.4, 4.5, 4.8, 6.3, 6.5, 9.10, or 9.11 above, Borrowers will request such consent or approval in writing with a conspicuous statement that failure to timely respond will constitute approval
of the item being submitted. Failure by Lender to respond by either approving or disapproving the item submitted within ten (10) days (or other applicable period specifically set forth in this Agreement) after receipt of the request for consent
or approval and all information required for the evaluation of such request shall constitute Lender’s approval of the item submitted for approval. 

  

	12.13	LOAN SALES AND PARTICIPATION; DISCLOSURE OF INFORMATION. Lender may sell or assign all or any portion (not less than $5,000,000) of its rights and obligations under the Loan with Borrowers’ prior
written approval (such approval not to be unreasonably withheld or delayed); provided, that, (i) during the existence of a Default, Lender shall not be required to sell or assign any minimum amount or obtain Borrowers’ approval, and
(ii) such approval shall be deemed granted if Borrowers fail to approve or disapprove such sale or assignment within 10 Business Days, following Lender’s request therefor. Lender, may, at any time and in its sole expense, grant
participations in the Loan. If Lender assigns or participates any portion (but not all) of its interest in the Loan, Lender shall become and remain the sole administrative agent under the Loan, and shall be Borrowers’ sole point of contact with
respect to the Loan. Lender may freely grant participations of all or any portion of the Loan. 

 Anything in this Agreement to
the contrary notwithstanding, and without the need to comply with any of the formal or procedural requirements of this Agreement, including this Section, any lender may at any time and from time to time pledge and assign all or any portion of its
rights under all or any of the Loan Documents to a Federal Reserve Bank; provided that no such pledge or assignment shall release such lender from its obligations thereunder. 
  

	12.14	 CAPITAL ADEQUACY. If Lender determines that compliance with any change in any law or regulation or with any guideline or request from
any central bank or other governmental agency (whether or not having the force of law) affects or would affect the amount of capital required or expected to be maintained by Lender, or any corporation controlling Lender, as a consequence of, or with
reference to, Lender’s or such corporation’s commitments or its making or maintaining advances below the rate which Lender or such corporation controlling Lender could have achieved but for such compliance with such change (taking into
account the policies of Lender or corporation with regard to capital), then Borrowers shall, from time to time, within forty (40) calendar days after written demand by Lender pay to Lender the additional amounts sufficient to

  

					
		 	50	  	Loan No. 1015003

	 	
compensate Lender or such corporation controlling Lender to the extent that Lender determines such increase in capital is allocable to Lender’s obligations hereunder. If Lender becomes
entitled to claim any additional amounts pursuant to this subsection, Lender shall provide Borrowers with not less than sixty (60) days’ notice specifying in reasonable detail the event by reason of which it is has become so entitled and
the additional amount required to fully compensate Lender for such additional cost or reduced amount together with a certificate as to any additional costs or amounts payable pursuant to the foregoing sentence submitted by Lender to Borrowers (which
certificate shall be conclusive in the absence of manifest error). 

  

	12.15	LENDER’S AGENTS. Lender may designate an agent or independent contractor to exercise any of Lender’s rights under this Agreement and any of the other Loan Documents. Any reference to Lender in
any of the Loan Documents shall include Lender’s agents, employees or independent contractors. Borrowers shall pay the reasonable costs of such agent or independent contractor either directly to such Person or to Lender in reimbursement of such
costs, as applicable. 

  

	12.16	TAX SERVICE. Lender is authorized to obtain, at Borrowers’ expense, a tax service contract with a third party vendor which shall provide tax information on the Property and Improvements satisfactory
to Lender. 

  

	12.17	WAIVER OF RIGHT TO TRIAL BY JURY. TO THE EXTENT PERMITTED BY APPLICABLE STATE LAW, EACH PARTY TO THIS AGREEMENT HEREBY EXPRESSLY WAIVES ANY RIGHT TO TRIAL BY JURY OF ANY CLAIM, DEMAND, ACTION OR CAUSE OF
ACTION (a) ARISING UNDER THE LOAN DOCUMENTS, INCLUDING, WITHOUT LIMITATION, ANY PRESENT OR FUTURE MODIFICATION THEREOF OR (b) IN ANY WAY CONNECTED WITH OR RELATED OR INCIDENTAL TO THE DEALINGS OF THE PARTIES HERETO OR ANY OF THEM WITH
RESPECT TO THE LOAN DOCUMENTS (AS NOW OR HEREAFTER MODIFIED) OR ANY OTHER INSTRUMENT, DOCUMENT OR AGREEMENT EXECUTED OR DELIVERED IN CONNECTION HEREWITH, OR THE TRANSACTIONS RELATED HERETO OR THERETO, IN EACH CASE WHETHER SUCH CLAIM, DEMAND, ACTION
OR CAUSE OF ACTION IS NOW EXISTING OR HEREAFTER ARISING, AND WHETHER SOUNDING IN CONTRACT OR TORT OR OTHERWISE; AND EACH PARTY HEREBY AGREES AND CONSENTS THAT ANY PARTY TO THIS AGREEMENT MAY FILE AN ORIGINAL COUNTERPART OR A COPY OF THIS SECTION
WITH ANY COURT AS WRITTEN EVIDENCE OF THE CONSENT OF THE PARTIES HERETO TO THE WAIVER OF ANY RIGHT THEY MIGHT OTHERWISE HAVE TO TRIAL BY JURY. 

  

	12.18	SEVERABILITY. If any provision or obligation under this Agreement and the other Loan Documents shall be determined by a court of competent jurisdiction to be invalid, illegal or unenforceable, that
provision shall be deemed severed from this Agreement and the other Loan Documents and the validity, legality and enforceability of the remaining provisions or obligations shall remain in full force as though the invalid, illegal, or unenforceable
provision had never been a part of this Agreement and the other Loan Documents; provided, however, that if the rate of interest or any other amount payable under the Note or this Agreement or any other Loan Document, or the right of
collectability therefore, are declared to be or become invalid, illegal or unenforceable, Lender’s obligations to make advances under the Loan Documents shall not be enforceable by Borrowers. 

 

	12.19	HEIRS, SUCCESSORS AND ASSIGNS. Except as otherwise expressly provided under the terms and conditions herein, the terms of the Loan Documents shall bind and inure to the benefit of the heirs, executors,
administrators, nominees, successors and assigns of the parties hereto. 

  

	12.20	TIME. Time is of the essence of each and every term herein. 

  

	12.21	HEADINGS. All article, section or other headings appearing in this Agreement and any of the other Loan Documents are for convenience of reference only and shall be disregarded in construing this Agreement
and any of the other Loan Documents. 

  

					
		 	51	  	Loan No. 1015003

	12.22	GOVERNING LAW AND CONSENT TO JURISDICTION. This Agreement and any claim, controversy or dispute arising under or related to this Agreement, the relationship of the parties, and/or the interpretation and
enforcement of the rights and duties of the parties will be governed by, and construed and enforced in accordance with, the laws of the State of New York without regard to any conflicts of law principles, except to the extent preempted by federal
laws. Borrowers and all persons and entities in any manner obligated to Lender under the Loan Documents consent to the jurisdiction of any federal or state court within the State of New York having proper venue and also consent to service of process
by any means authorized by New York or federal law. 

  

	12.23	GOVERNMENTAL COMPLIANCE. The federal regulations issued with respect thereto require all financial institutions to obtain, verify and record certain information that identifies individuals or business
entities which open an “account” with such financial institution. Consequently, Lender may from time-to-time request, and each Borrower shall provide to Lender, such Borrower’s name, address, tax identification number and/or such
other identification information as shall be necessary for Lender to comply with federal law. An “account” for the purposes of this Section may include, without limitation, a deposit account, cash management service, a transaction or asset
account, a credit account, a loan or other extension of credit, and/or other financial services product. 

  

	12.24	INTENTIONALLY DELETED. 

  

	12.25	COUNTERPARTS. To facilitate execution, this document may be executed in as many counterparts as may be convenient or required. It shall not be necessary that the signature of, or on behalf of, each party,
or that the signature of all persons required to bind any party, appear on each counterpart. All counterparts shall collectively constitute a single document. It shall not be necessary in making proof of this document to produce or account for more
than a single counterpart containing the respective signatures of, or on behalf of, each of the parties hereto. Any signature page to any counterpart may be detached from such counterpart without impairing the legal effect of the signatures thereon
and thereafter attached to another counterpart identical thereto except having attached to it additional signature pages. 

  

	12.26	IIT. Notwithstanding anything to the contrary contained herein, for the avoidance of doubt Lender hereby acknowledges and agrees that none of Industrial Income Trust, Inc., Industrial Income Operating
Partnership LP, or any of their subsidiaries, other than Borrower and Guarantor, will have any obligations under this Agreement or the Loan Documents. 

  

	12.27	INTEGRATION; INTERPRETATION. THE LOAN DOCUMENTS CONTAIN OR EXPRESSLY INCORPORATE BY REFERENCE THE ENTIRE AGREEMENT OF THE PARTIES WITH RESPECT TO THE MATTERS CONTEMPLATED THEREIN AND SUPERSEDE ALL PRIOR
NEGOTIATIONS OR AGREEMENTS, WRITTEN OR ORAL. THE LOAN DOCUMENTS SHALL NOT BE MODIFIED EXCEPT BY WRITTEN INSTRUMENT EXECUTED BY ALL PARTIES. ANY REFERENCE TO THE LOAN DOCUMENTS INCLUDES ANY AMENDMENTS, RENEWALS OR EXTENSIONS NOW OR HEREAFTER APPROVED
BY LENDER IN WRITING. 

  

	12.28	TAX SHELTER MATTERS. 

  

	 	(a)	Tax Shelter Regulations. Neither any Borrower, the Guarantor, nor any subsidiary of any of the foregoing intends to treat the Loan or the transactions contemplated by this Agreement and the other Loan
Documents as being a “reportable transaction” (within the meaning of Treasury Regulation Section 1.6011-4). If any Borrower, or any other party to the Loan determines to take any action
inconsistent with such intention, Borrowers will promptly notify Lender thereof. If Borrowers so notify Lender, Borrowers acknowledge that Lender may treat the Loan as part of a transaction that is subject to Treasury Regulation Section 301.6112-1, and Lender will maintain the lists and other records, including the identity of the applicable party to the Loan as required by such Treasury Regulation. 

 

	 	(b)	Confidentiality. Notwithstanding anything to the contrary set forth herein or in any other written or oral understanding or agreement to which the parties hereto are parties or by which they are bound, the
parties hereto acknowledge and agree that (i) any obligations of confidentiality contained herein and therein do not apply and have not applied from the commencement of discussions between the parties to the tax treatment and tax structure of
the transactions contemplated by the Loan Documents (and any related transactions or arrangements), and (ii) each party (and each of its employees, representatives, or other agents) may disclose to any and all Persons as required, without
limitation of any kind, the tax treatment and tax structure of the transactions contemplated by the Loan Documents and all materials of any kind (including opinions or other tax analyses) that are provided to such party relating to such tax
treatment and tax structure, all within the meaning of Treasury Regulations Section 1.6011-4; provided, however, that each party recognizes that the privilege each has to maintain, in its
sole discretion, with regard to the confidentiality of a communication relating to the transactions contemplated by the Loan Documents, including a confidential communication with its attorney or a confidential communication with a federally
authorized tax practitioner under Section 7525 of the Internal Revenue Code, is not intended to be affected by the foregoing. 

  

					
		 	52	  	Loan No. 1015003

	12.29	NO WAIVER. No previous waiver and no failure or delay by Lender in acting with respect to the terms of the Note or this Agreement shall constitute a waiver of any breach, default, or failure of condition
under the Note, this Agreement or the obligations secured thereby. A waiver of any term of the Note, this Agreement or of any of the obligations secured thereby must be made in writing and shall be limited to the express written terms of such
waiver. 

  

	12.30	JOINT AND SEVERAL LIABILITY. The liability of each Borrower obligated in any manner hereunder and under any of the Loan Documents shall be joint and several. 

 

	12.31	ELECTRONIC TRANSMISSION OF DATA. Lender and Borrowers agree that certain data related to the Loan (including confidential information, documents, applications and reports) may be transmitted
electronically, including transmission over the Internet. This data may be transmitted to, received from or circulated among agents and representatives of Borrowers and/or Lender and their affiliates and other persons involved with the subject
matter of this Agreement. Each Borrower acknowledges and agrees that (a) there are risks associated with the use of electronic transmission and that Lender does not control the method of transmittal or service providers, (b) Lender has no
obligation or responsibility whatsoever and assumes no duty or obligation for the security, receipt or third party interception of any such transmission, and (c) BORROWERS WILL RELEASE, HOLD HARMLESS AND INDEMNIFY LENDER FOR, FROM AND AGAINST
ANY CLAIM, DAMAGE OR LOSS, INCLUDING THAT ARISING IN WHOLE OR PART FROM LENDER’S STRICT LIABILITY OR SOLE, COMPARATIVE OR CONTRIBUTORY NEGLIGENCE, WHICH IS RELATED TO THE ELECTRONIC TRANSMISSION OF DATA. 

 

	12.32	POWERS OF ATTORNEY. The powers of attorney granted by each Borrower to Lender in this Agreement shall (i) be of no effect unless and until there is a Default under the Loan that has occurred and is
continuing and (ii) be unaffected by the disability of the principal so long as any portion of the Loan remains unpaid or unperformed. Lender shall have no obligation to exercise any of the foregoing rights and powers in any event. Lender
hereby discloses that it may exercise the foregoing powers of attorney for Lender’s benefit, and such authority need not be exercised for Borrowers’ best interest. 

 

	12.33	RULES OF CONSTRUCTION. The words “Borrower” and “Borrowers” as used herein shall include both the named Borrowers and any other person at any time assuming or otherwise becoming
primarily liable for all or any part of the obligations of the named Borrowers under the Note and the other Loan Documents. If this Agreement is executed by more than one Person, the term “Borrower” shall include all such Persons. The word
“Lender” as used herein shall include Lender, its successors, assigns and affiliates. 

  

					
		 	53	  	Loan No. 1015003

	12.34	USE OF SINGULAR AND PLURAL; GENDER. When the identity of the parties or other circumstances make it appropriate, the singular number includes the plural, and the masculine gender includes the feminine
and/or neuter. 

  

	12.35	EXHIBITS, SCHEDULES AND RIDERS. All exhibits, schedules, riders and other items attached hereto are incorporated into this Agreement by such attachment for all purposes. 

 

	12.36	INCONSISTENCIES. In the event of any inconsistencies between the terms of this Agreement and the terms of any of the other Loan Documents, the terms of this Agreement shall prevail. 

 

	12.37	ADVERTISING; SIGNS. In connection with the Loan, each Borrower hereby agrees that Wells Fargo & Company and its subsidiaries (“Wells Fargo”) may publicly identify details
of the Loan in Wells Fargo advertising and public communications of all kinds, including, but not limited to, press releases, direct mail, newspapers, magazines, journals, e-mail, internet advertising and communications, and the placement on the
Properties of reasonable signs standard to construction loan transactions stating that construction financing is being provided by Wells Fargo and any other lenders or participants in the Loan. Such details shall be limited to, the name of the
Properties, the address of the Properties, the amount of the Loan, the date of the closing and a description of the size/location of the Properties. 

  

	12.38	SPECIAL REPRESENTATIONS, CONSENTS AND WAIVERS CONCERNING CO-BORROWERS. 

  

	 	(a)	The parties hereto recognize and acknowledge that a Borrower has advanced to it under the Loan an aggregate principal amount in excess of the borrowing that would otherwise be supported by real property collateral
encumbered under the Security Instruments. The Loan has been established in the manner provided herein (and with the possible result referred to in the foregoing sentence) at the express request of, and to accommodate the administrative and
operational requirements of, the Borrowers. Specifically, the Loan might have been established to provide a limit on direct borrowings by Borrowers consistent with the specific borrowing base limitations imposed by real property collateral owned by
such Borrowers, with additional credit needs of such Borrowers in excess thereof being accommodated by inter-company loans from Borrower(s) with excess borrowing capacity to such other Borrowers requiring additional funds. However, for
administrative and operational reasons imposed by the Borrowers, as aforesaid, the Loan has been established as provided herein, but with the intention, as confirmed in subsection (b) below, that the Borrowers ultimately share, among themselves
repayment and/or reimbursement obligations under the Loan to the same extent as if such borrowings had been made under the alternative disbursement procedure described in the preceding sentence. In addition, it is further recognized and acknowledged
that (i) each Borrower shall directly and indirectly benefit from the expansion of business operations, as facilitated by the Loan, of each other Borrower, including, without limitation, the present and future contracting for goods and services
as between the Borrowers in respect of their business operations, and (ii) Lender has no intention or obligation to track the disbursement or use of Loan proceeds as between the various Borrower entities. 

 

	 	(b)	 In connection with its joint and several obligations under the Loan Documents, each Borrower waives: (i) any defense based upon any legal
disability or other defense of any other Borrower, or by reason of the cessation or limitation of the liability of any other Borrower from any cause other than full payment of all sums payable under the Note or any of the other Loan Documents;
(ii) any defense based upon any lack of authority of the officers, directors, partners or agents acting or purporting to act on behalf of any 

  

					
		 	54	  	Loan No. 1015003

	 	
Borrower or any principal thereof or any defect in the formation of any Borrower or any such principal; (iii) any defense based upon the application by any Borrower of the proceeds of the
Loan for purposes other than the purposes permitted under this Agreement or any other Loan Document; (iv) any and all rights and defenses arising out of an election of remedies by the Lender; (v) any defense based upon Lender’s
failure to disclose any information concerning any other Borrower’s financial condition or any other circumstances bearing on any other Borrower’s ability to pay all sums payable under the Notes or any of the other Loan Documents;
(vi) any defense based upon any statute or rule of law which provides that the obligation of a surety must be neither larger in amount nor in any other respects ore burdensome than that of a principal; (vii) any defense based upon the
Lender’s election, in any proceeding instituted under the Federal Bankruptcy Code, of the application of Section 1111(b)(2) of the Federal Bankruptcy Code or any successor statute; (viii) any defense based upon, any borrowing or any
grant of a security interest under Section 364 of the Federal Bankruptcy Code; (ix) any right of subrogation, any right to enforce any remedy which Lender may have against any other Borrower and any right to participate in, or benefit
from, any security for the Note or the other Loan Documents now or hereafter held by Lender; and (x) the benefit of any statute of limitations affecting the liability of each Borrower or the enforcement hereof. Each Borrower agrees that the
payment of all sums payable under the Note or any of the other Loan Documents or any part thereof or other act which tolls any statute of limitations applicable to the Note or other Loan Documents shall similarly operate to toll the statute of
limitations applicable to each Borrower’s liability hereunder. During the existence of a Default, Lender may (A) apply security and direct the order or manner of sale thereof as the Lender in its sole discretion may determine;
(B) release, substitute or add any one or more endorsers of the Note or guarantors of Borrowers’ obligations under the Note or the other Loan Documents; and (C) apply payments received by Lender from Borrowers to any obligations of
Borrowers to the Lender, in such order as Lender shall determine in its sole discretion. If all or any portion of the obligations of any Borrowers are paid or performed, the obligations of each other Borrower hereunder shall continue and shall
remain in full force and effect in the event that all or any part of such payment or performance is avoided or recovered directly or indirectly from Lender as a preference, fraudulent transfer or otherwise under the Bankruptcy Code or other similar
laws, irrespective of full payment and performance of all of the indebtedness and obligations evidenced and secured by the Loan Documents. Each Borrower acknowledges that: (a) the obligations under the Loan Documents are complex in nature,
(b) numerous possible defenses to the enforceability of these obligations may presently exist and/or may arise hereafter, and (c) as part of the Lender’s consideration for entering into these transactions, the Lender has specifically
bargained for the waiver and relinquishment by each Borrower of all such defenses, and each Borrower has had the opportunity to seek and receive legal advice from skilled legal counsel in the area of financial transactions of the type contemplated
herein. Given all of the above, each Borrower does hereby represent and confirm to Lender that each Borrower is fully informed regarding, and thoroughly understands: (i) the nature of all such possible defenses, (ii) the circumstances
under which such defenses may arise, (iii) the benefits which such defenses might confer upon Borrower, and (iv) the legal consequences to Borrower of waiving such defenses. Each Borrower acknowledges that all of the informed waivers
herein shall be fully enforceable by the Lender, and that Lender is induced to enter into this transaction in material reliance upon the presumed full enforceability thereof. 

 

	 	(c)	Without limiting subsection (b) above, and except as otherwise provided in this Agreement, each Borrower hereby specifically waives presentment, demand, protest and notice of any kind and without limiting the
generality of the foregoing or any provision of subsection (b) above, each Borrower further expressly waives to the extent permitted by law any and all rights and defenses, including, without limitation, any rights of subrogation,
reimbursement, indemnification and contribution, which might otherwise be available to such Borrower. 

  

					
		 	55	  	Loan No. 1015003

 [The remainder of this page intentionally left blank; signature pages follow.] 

  

					
		 	56	  	Loan No. 1015003

 IN WITNESS WHEREOF, Borrowers and Lender have duly executed and delivered this Agreement as of the date
first written above. 
  

			
	“LENDER”
	
	 WELLS FARGO BANK, NATIONAL ASSOCIATION,

a national banking association

		
	By:	 	 /s/ Craig V. Koshkarian

	Name:	 	Craig V. Koshkarian
	Title:	 	Vice President

  

					
		 		  	Loan No. 1015003

									
	NOTICE OF INDEMNIFICATION:	 		 	“BORROWERS”
			
	EACH BORROWER HEREBY ACKNOWLEDGES AND AGREES THAT THIS AGREEMENT CONTAINS CERTAIN INDEMNIFICATION PROVISIONS PURSUANT TO SECTIONS 12.1 AND 12.31 HEREOF.	 		 	BLUEGRASS DC II LLC, formerly known as IIT Bluegrass DC II LLC
	 		 	LEHIGH VALLEY CROSSING DC I LLC, formerly known as IIT Lehigh Valley Crossing DC I LLC
	 		 	LEHIGH VALLEY CROSSING DC II LLC, formerly known as IIT Lehigh Valley Crossing DC II LLC
		 		 	LEHIGH VALLEY CROSSING DC III LLC, formerly known as IIT Lehigh Valley Crossing DC III LLC
		 		 	MIAMI DC III LLC, formerly known as IIT Miami DC III LLC
		 		 	MIAMI DC IV LLC, formerly known as IIT Miami DC IV LLC
		 		 	TAMARAC COMMERCE CENTER DC II LLC, formerly known as IIT Tamarac Commerce Center II LLC
		 		 	TAMARAC COMMERCE CENTER DC III LLC, formerly known as IIT Tamarac Commerce Center III LLC
		 		 	MIAMI DC III LAND LLC, formerly known as IIT Miami DC III Land LLC,
		 		 	each a Delaware limited liability company
				
		 		 	By:	 	 /s/ Lainie P. Minnick

		 		 	Name:	 	Lainie P. Minnick
		 		 	Title:	 	Senior Vice President, Finance and Treasurer
			
		 		 	CAJON DC LP, a Delaware limited partnership, formerly known as IIT Cajon DC LP
				
		 		 	By:	 	Cajon DC GP LLC, a Delaware limited liability company, formerly known as IIT Cajon DC GP LLC, its general partner
					
		 		 		 	By:	 	 /s/ Lainie P. Minnick

		 		 		 	Name:	 	Lainie P. Minnick
		 		 		 	Title:	 	Senior Vice President, Finance and Treasurer
			
		 		 	REDLANDS DC LP, a Delaware limited partnership, formerly known as IIT Redlands DC LP
				
		 		 	By:	 	Redlands DC GP LLC, a Delaware limited liability company, formerly known as IIT Redlands DC GP LLC, its general partner
					
		 		 		 	By:	 	 /s/ Lainie P. Minnick

		 		 		 	Name:	 	Lainie P. Minnick
		 		 		 	Title:	 	Senior Vice President, Finance and Treasurer

  

					
		 		  	Loan No. 1015003

 SCHEDULE 1 – BORROWERS AND PROPERTIES 

 

			
	 Borrower
	  	 Address

	 Redlands DC LP
	  	1300 California St., Redlands, CA
		
	 Cajon DC LP
	  	6207 North Cajon Blvd., San Bernardino, CA
		
	 Miami DC III LLC
	  	11001 NW 124th St., Medley, FL
		
	 Miami DC IV LLC
	  	11040 NW 124th St., Medley, FL
		
	 Miami DC III Land LLC
	  	10910 NW 124th St., Medley FL
		
	 Tamarac Commerce Center DC II LLC
	  	6201 North Nob Hill Road, Tamarac, FL
		
	 Tamarac Commerce Center DC III LLC
	  	6900 Hiatus Road, Tamarac, FL
		
	 Lehigh Valley Crossing DC I LLC
	  	2929 Schoeneck Road, Macungie, PA
		
	 Lehigh Valley Crossing DC II LLC
	  	3100 Alburtis Road, Macungie, PA
		
	 Lehigh Valley Crossing DC III LLC
	  	2918 Schoeneck Road, Macungie, PA
		
	 Bluegrass DC II LLC
	  	1870 McFarland Road, Alpharetta, GA

  

					
		 		  	Loan No. 1015003

 SCHEDULE 2 – BANK OF AMERICA LETTERS OF CREDIT 

 

									
	 Number
	  	Amount	 	  	Expiration
Date	  	 Beneficiary

	 00000003129121
	  	$	169,975.00	  	  	9/27/2016	  	County Administrator, Broward County
	 00000068106154
	  	$	248,567.00	  	  	9/12/2016	  	County Administrator, Broward County
	 00000068106155
	  	$	313,603.00	  	  	9/12/2016	  	County Administrator, Broward County
	 00000068107909
	  	$	114,114.59	  	  	11/19/2015	  	City of Tamarac
	 00000068108606
	  	$	125,376.00	  	  	1/2/2016	  	Lower Macungie Township
	 00000068108607
	  	$	264,904.08	  	  	1/2/2016	  	Lower Macungie Township
	 00000068107910
	  	$	419,989.59	  	  	11/19/2015	  	Lower Macungie Township

  

					
		 		  	Loan No. 1015003

 SCHEDULE 2.10 - ALLOCATED LOAN AMOUNTS 

 

							
	 Borrower
	  	 Address
	  	Allocated Loan Amount	 
	 Redlands DC LP
	  	1300 California St., Redlands, CA	  	$	33,169,000	  
			
	 Cajon DC LP
	  	6207 North Cajon Blvd., San Bernardino, CA	  	$	33,980,000	  
			
	 Miami DC III LLC
	  	11001 NW 124th St., Medley, FL	  	$	5,498,000	  
			
	 Miami DC IV LLC
	  	11040 NW 124th St., Medley, FL	  	$	4,890,000	  
			
	 Miami DC III Land LLC
	  	10910 NW 124th St., Medley FL	  	$	623,000	  
			
	 Tamarac Commerce Center DC II LLC
	  	6201 North Nob Hill Road, Tamarac, FL	  	$	6,000,000	  
			
	 Tamarac Commerce Center DC III LLC
	  	6900 Hiatus Road, Tamarac, FL	  	$	2,350,000	  
			
	 Lehigh Valley Crossing DC I LLC
	  	2929 Schoeneck Road, Macungie, PA	  	$	14,750,000	  
			
	 Lehigh Valley Crossing DC II LLC
	  	3100 Alburtis Road, Macungie, PA	  	$	7,900,000	  
			
	 Lehigh Valley Crossing DC III LLC
	  	2918 Schoeneck Road, Macungie, PA	  	$	4,960,000	  
			
	 Bluegrass DC II LLC
	  	1870 McFarland Road, Alpharetta, GA	  	$	5,880,000	  

  

					
		 		  	Loan No. 1015003

 SCHEDULE 6.3 - ORGANIZATIONAL CHART 

[See attached Organizational Chart] 

  

					
		 		  	Loan No. 1015003

 

 

  

					
		 		  	Loan No. 1015003

 SCHEDULE 6.6 - LITIGATION 

None. 

  

					
		 		  	Loan No. 1015003

 SCHEDULE 6.22 - LEASES 

 

	1.	Lease Agreement by and between Tamarac Commerce Center II, LLC, a Delaware limited liability company, and Blue Aerospace LLC, a Florida limited liability company, dated October 22, 2014, as amended by that certain
First Amendment to Lease dated as of June 15, 2015. 

  

					
		 		  	Loan No. 1015003

 EXHIBIT A - DESCRIPTION OF PROPERTIES 

EXHIBIT A-1 – REDLANDS PROPERTY 
 The
Land referred to herein is situated in the State of California, County of San Bernardino, City of Redlands, and described as follows: 
 Parcel 1, as shown
on Parcel Map No. 19496, Book 243 Pages 1 through 3, in the City of Redlands, County of San Bernardino, State of California, filed for record September 14, 2014 in the County Recorder’s Office of San Bernardino County. 

NEW APN: 0292-053-16-0000 
 EXHIBIT A-2 –
CAJON PROPERTY 
 The Land referred to herein is situated in the State of California, County of San Bernardino, City of San Bernardino, and described as
follows: 
 Parcel 1, as shown on Parcel Map No. 19395 in Book 241, Pages 80-82, filed in the Office of the recorder of the County of San Bernardino,
State of California. 
 APN: 0262-042-39 

EXHIBIT A-3 – MIAMI III PROPERTY 

Lot 2, Block 2, of PANAMERICAN NORTH BUSINESS PARK, according to the Plat thereof, as recorded in Plat Book 162, Page 51, of the Public Records of
Miami-Dade County, Florida, 
 LESS AND EXCEPT that portion within Lot 2, Block 2 encumbered by that certain Easement recorded December 19, 2003 in
Official Records Book 21920, Page 3428, of the Public Records of Miami-Dade County, Florida. 
 Together with Easements as set forth in Declaration of
Covenants, Conditions and Restrictions for Pan American North Business Park, recorded April 13, 2004 in Official Records Book 22208, Page 3829, and May 21, 2004 in Official Records Book 22325, Page 3641, as amended by First Amendment to
Declaration of Covenants, Conditions and Restrictions recorded May 3, 2007 in Official Records Book 25586, Page 3989, all of the Public Records of Miami-Dade County, Florida. 

EXHIBIT A-4 – MIAMI IV PROPERTY 

Lots 3, 4, 5, 10, 11, and 12, Block 4 of PANAMERICAN NORTH BUSINESS PARK, according to the Plat thereof, as recorded in Plat Book 162, Page 51, of the Public
Records of Miami-Dade County, Florida. 
 Together with Easements asset forth In Declaration of Covenants, Conditions and Restrictions for Pan American
North Business Park, recorded in Official Records Book 22208, Page 3829, and In Official Records Book 22325, Page 3641, as amended by First Amendment to Declaration of Covenants, Conditions and Restrictions recorded In Official Records Book 25586,
Page 3989, all of the Public Records of Miami-Dade County, Florida. 

  

					
		 		  	Loan No. 1015003

 EXHIBIT A-5 – MIAMI III LAND PROPERTY 

Lots 6 and 7, Block 4, of PANAMERICAN NORTH BUSINESS PARK, according to the Plat thereof, as recorded in Plat Book 162, Page 51, of the Public Records of
Miami-Dade County, Florida. 
 Together with Easements as set forth in Declaration of Covenants, Conditions and Restrictions for Pan American North Business
Park, recorded April 13, 2004 in Official Records Book 22208, Page 3829, and May 21, 2004 in Official Records Book 22325, Page 3641, as amended by First Amendment to Declaration of Covenants, Conditions and Restrictions recorded
May 3, 2007 in Official Records Book 25586, Page 3989, all of the Public Records of Miami-Dade County, Florida. 
 EXHIBIT A-6 –
TAMARAC COMMERCE CENTER II PROPERTY 
 PARCEL 1: (Fee Parcel) 

The South One-Half (S 1/2) of Tract Four (4), of the Subdivision of Section 7, Township 49 South, Range 41 East, according to the FLORIDA FRUITLANDS
COMPANY’S SUBDIVISION NO. 2, recorded in Plat Book 1 at page 102 of the public records of Palm Beach County, Florida. 
 LESS that portion of said
South one-half (S 1/2) of Tract Four (4) lying within Thirty-Five feet (35’) of the East section line of said Section 7, measured at right angles and less that portion conveyed to Broward County by Warranty Deed recorded
December 8, 2011 in Official Records Book 48352, Page 724, of the Public Records of Broward County, Florida. 
 NOW KNOWN AS: 

Parcel “A” of “TAMARAC COMMERCE II”, according to the map or plat thereof as recorded in Plat Book 181, Pages 32 and 33, of the Public
Records of Broward County, Florida. 
 PARCEL 2: (Easement Parcel as created by Temporary Construction Easement Agreement recorded in Official Records
Instrument Number 112887955, of the Public Records of Broward County, Florida.) 
 A portion of Parcel “A”, “S&N PLAT NO.TWO”
according to the plat thereof, as recorded in Plat Book 171 at Page 112 of the Public Records of Broward County, Florida more particularly described as follows: 

Commence at the most Southeast corner of Parcel “A” “S&N PLAT NO.TWO” according to the plat thereof, as recorded in Plat Book 171 at
Page 112 of the Public Records of Broward County, Florida; thence run South 89 degrees 21 minutes 33 seconds West, along the South boundary line of said Parcel “A”, for 941.74 feet to the Point of Beginning of a strip of land 15 feet in
width lying 7.5 feet on each side of and parallel with the following described centerline; thence North 00 degrees 38 minutes 28 seconds West for 79.18 feet to the Point of Termination of said centerline. 

Sidelines of all easement are to be lengthened or shortened so as to form a continuous 15 foot wide strip of land. 

Sidelines at the Point of Beginning are to be lengthened or shortened so as to intersect the South boundary line of said parcel “A”. 

Sidelines at the Point of Termination are to be lengthened or shortened so as to intersect the North line of a 15 foot Water and Sewer Utility Easement,
recorded in Official Records Book 39547, Page 1135, of the Public Records of Broward County, Florida. 
 All lying and being in the Northeast 1/4 of
Section 7, Township 49 South, Range 41 East, City of Tamarac, Broward County, Florida. 

  

					
		 		  	Loan No. 1015003

 EXHIBIT A-7 – TAMARAC COMMERCE CENTER III PROPERTY 

A part of Tract 8, Section 7, Township 49 South, Range 41 East, according to the Plat of FLORIDA FRUIT LANDS COMPANY’S SUBDIVISION NO. 2, as
recorded in Plat Book 1, Page 102, of the Public Records of Palm Beach County, Florida, being more particularly described as follows: 
 FROM the Southwest
corner of said Tract 8, run N. 89°56’40” E. along the South line of said Tract 8 for 15.0 feet to the POINT OF BEGINNING: 
 THENCE N.
00°18’43” W. parallel with the West line of said Tract 8, for 583.73 feet to the point of curvature of a curve concave to the Southeast and having a radius of 25.0 feet: 

THENCE Northeasterly along the arc of said curve for 39.41 feet through a central angle of 90°18’43” to the point of tangency of said curve;

 THENCE East, parallel with and 38.0 feet South of the North line of said Tract 8 for 332.91 feet: 

THENCE S. 00°18’43” E. parallel with the West line of said Tract 8 for 608.52 feet to the South line of said Tract 8: 

THENCE S. 89°56’40” W. along said South line 358.04 feet to the POINT OF BEGINNING, and situate in Broward County, Florida. 

LESS lands conveyed to the City of Tamarac by Warranty Deed recorded August 7, 1997 in Official Records Book 26820, Page 866, of the Public Records of
Broward County, Florida. 
 NOW KNOW AS: 
 Parcel
“A”, of “TAMARAC COMMERCE III”, according to the Map or Plat thereof as recorded in Plat Book 181, Pages 28 and 29, of the Public Records of Broward County, Florida. 

  

					
		 		  	Loan No. 1015003

 EXHIBIT A-8 – LEHIGH VALLEY I PROPERTY 

Lower Macungie Township, Lehigh County, Commonwealth of Pennsylvania 

BEGINNING at a concrete monument found at a point formed by the intersection of the Easterly reputed dedicated Township right of way line of Schoenech Road
(A.K.A. T-480) with the dividing line between APN No. 547319139714-00001 and APN. No. 54740001554 (lands n/f James E. and Joyce E. Eisenhard) and from said point of beginning running, thence; 

1. Along said dividing line between APN No. 547319139714-00001 and APN No. 54740001554, South 84 degrees - 11 minutes - 45 seconds East, a distance of
399.66 feet to a point, thence; 
 2. Along the dividing line between APN No. 547319139714-00001 and APN No. 547400437929 (land n/f Hoover Avenue
Development Co.), South 84 degrees - 12 minutes - 43 seconds East, a distance of 450.36 feet to a point, thence; 
 3. Along the dividing line between APN
No. 547319139714-00001 and APN No. 547400924807 (lands n/f Lower Macungie Self Storage), South 84 degrees - 12 minutes - 21 seconds East, a distance of 577.92 feet to a concrete monument found, thence; along the dividing line between APN
No. 547319139714-00001 and APN No. 547410626833 (lands n/f Grace Kirby), the following two (2) courses: 
 4. South 10 degrees - 11 minutes -
36 seconds East, a distance of 72.93 feet to a concrete monument found, thence; 
 5. South 84 degrees - 45 minutes - 35 seconds East, a distance of 296.16
feet to a point, thence; 
 6. Proceeding through the interior of APN No. 547319139714-00001 and along the proposed dividing line between proposed
Parcel “A” and proposed Parcel “B”, South 04 degrees – 56 minutes - 18 seconds West, a distance of 610.10 feet to a point, thence; 

7. Continuing through said interior of APN No. 547319139714-00001 and along the proposed dividing line between proposed Parcel “A” and
proposed Parcel “C’, North 85 degrees – 03 minutes - 42 seconds West, a distance of 1,658.53 feet to a point on the aforementioned Easterly line of Schoeneck Road, thence; 

8. Along said Easterly line, North 01 degrees - 54 minutes - 22 seconds West, a distance of 708.46 feet to the point and place of beginning. 

EXHIBIT A-9 – LEHIGH VALLEY II PROPERTY 

Lower Macungie Township, Lehigh County, Commonwealth of Pennsylvania 

Beginning at a concrete monument found at a point formed by the intersection of the Northerly reputed dedicated Township right of way line of Alburtis Road
(A.K.A. S.R. 3002, A.K.A. L.R. 39020) with the dividing line between APN No. 547319139714-00001 and APN No. 547339167786 (lands n/f Ray A. Leibensperger) and from said point of beginning running, thence; along said Northerly line of
Alburtis Road, the following two (2) courses: 
 1. North 84 degrees - 38 minutes - 04 seconds West, a distance of 989.54 feet to a point concrete
monument found at a point of curvature, thence; 
 2. Along a curve to the left, having a radius of 160.00 feet, a central angle of 52 degrees – 47
minutes - 29 seconds, an arc length of 147.42 feet, bearing a chord of South 68 degrees – 58 minutes - 11 seconds West, a chord distance of 142.26 feet to a point, thence; proceeding through the interior of APN No. 547318386447-00001 and
APN No. 547319139714-00001 and along the proposed dividing line between proposed Parcel “B” and proposed Parcel “C”, the following two (2) courses: 

3. North 46 degrees - 51 minutes - 39 seconds West, a distance of 128.32 feet to a point, thence; 

  

					
		 		  	Loan No. 1015003

 4. North 85 degrees - 03 minutes - 42 seconds West, a distance of 158.38 feet to a point, thence; 

5. Continuing through the interior of APN No. 547319139714-00001 and along the proposed dividing line between proposed Parcel “B” and
proposed Parcel “A”, North 04 degrees – 56 minutes - 18 seconds East, a distance of 610.10 feet to a point, thence; 
 6. Along the dividing
line between APN No. 547319139714-00001 and APN No. 547410626833 (lands n/f Grace Kirby) & APN No. 547420518536 (lands n/f Jessica Treichler and J. Treichler), South 84 degrees - 45 minutes - 35 seconds East, a distance of
1,348.66 feet to a concrete monument found at a point on the Southwesterly reputed dedicate Township right of way of Pennsylvania State Highway Route 100 (A.K.A. S.R. 0100, A.K.A. L.R. 486), thence; 

7. Along said southwesterly right of way, South 61 degrees - 41 minutes - 05 seconds East, a distance of 265.70 feet to a concrete monument found, thence;

 8. Along the dividing line between APN No. 547319139714-00001 and APN No. 547339298592 (lands n/f Howard D. Moyer), South 02 degrees - 49
minutes - 13 seconds West, a distance of 90.33 feet to a point, thence; along the dividing line between APN No. 547319139714-00001 and APN No. 547339167786 (lands n/f Ray A. Leibensperger), the following two (2) courses: 

9. North 84 degrees - 07 minutes - 57 seconds West, a distance of 213.70 feet to a point, thence; 

10. South 05 degrees - 40 minutes - 07 seconds West, a distance of 435.24 feet to the point and place of beginning. 

EXHIBIT A-10 – LEHIGH VALLEY III PROPERTY 

PARCEL 1: 
 ALL THAT CERTAIN tract or parcel of ground situated
on the Westerly side of Schoeneck Road (T-480) in the Township of Lower Macungie, County of Lehigh, Pennsylvania, being Lot A on the Map entitled “Subdivision Plan, Preliminary/Final Subdivision and Land Development Plans for IIT Valley
Crossings DC, LLC, Proposed Warehouse at Lehigh Valley South Industrial Park,” recorded in the Recorder of Deeds Office of Lehigh County on December 11, 2014 as Instrument Nos. 2014033351 through 2014033355 and being more fully bounded and
described as follows, to wit: 
 BEGINNING at a point on the Westerly ultimate right-of-way line of Schoeneck Road (a.k.a. T-480), variable width
right-of-way, at the intersection of the dividing line between A.P.N. 546399379125-00001 and A.P.N. 546398772818-0001, lands now or formerly Polaris South Realty, L.P., and from said point of beginning running thence: 

THE following two (2) courses and distances along the dividing line between A.P.N. 546399379125-00001 and A.P.N. 546398772818-0001; 

1) South 85 degrees 56 minutes 31 seconds West, a distance of 486.43 feet to a point, thence; 

2) South 86 degrees 06 minutes 37 seconds West, a distance of 312.03 feet to a point, thence; 

  

					
		 		  	Loan No. 1015003

 The following three (3) courses and distances along the dividing line between A.P.N. 546399379125-00001 and
A.P.N. 546398553594-00001, lands now or formerly Liberty Property, L.P.: 
 3) North 08 degrees 33 minutes 28 seconds East, a distance of 152.47 feet to a
point, thence; 
 4) North 10 degrees 37 minutes 56 seconds West, a distance of 100.08 feet to a point, thence; 

5) North 10 degrees 48 minutes 22 seconds West, a distance of 219.07 feet to a point, thence; 

The following two (2) courses and distances along a line running through A.P.N. 546399379125-0001, being the dividing line between Lot A and Lot B of
said Proposed Warehouse Preliminary/Final Subdivision and Land Development Plans: 
 6) North 79 degrees 28 minutes 54 seconds East, a distance of 723.14
feet to a point, thence; 
 7) South 89 degrees 11 minutes 15 seconds East, a distance of 130.03 feet to a point on the Westerly ultimate right-of-way line
of Schoeneck Road, thence; 
 8) Along the Westerly ultimate right-of-way line of Schoeneck Road, South 00 degrees 48 minutes 45 seconds West, a distance of
538.96 feet to the point and place of beginning. 
 CONTAINING 413,440 square feet or 9.491 acres, more or less. 

BEING the same premises which IIT Valley Crossings DC LLC, a Delaware limited liability company, by Deed dated January 7, 2015 and recorded
January 8, 2015 in the Office of the Recorder of Deeds in and for Lehigh County, Pennsylvania in Instrument Number 2015000638, granted and conveyed unto IIT Lehigh Valley Crossing DC III LLC, a Delaware limited liability company, in fee.

 AND the said IIT Lehigh Valley Crossing DC III, LLC by name change filed with the Delaware Department of State on November 3, 2015 is now known as
Lehigh Valley Crossing DC III, LLC, a Delaware limited liability company. 
 PARCEL 2: 

Together with those certain perpetual, non-exclusive easements for vehicle and pedestrian access, stormwater system, and sanitary sewer, as fully set forth in
that certain Access, Easement, Maintenance and Temporary Construction Agreement by and between IIT Valley Crossings DC LLC, a Delaware limited liability company, and IIT Lehigh Valley Crossing DC III LLC, a Delaware limited liability company, dated
October 19, 2015 and recorded October 20, 2015 in the Office of the Recorder of Deeds in and for Lehigh County, Pennsylvania in Instrument Number 2015031421. 

EXHIBIT A-11 – BLUEGRASS II PROPERTY 

RECORD LEGAL FOR PARCEL I: 
 ALL THOSE TRACTS OR PARCELS
OF LAND LYING AND BEING IN LAND LOTS 963, 982, AND 1034 OF THE 1ST SECTION, 2ND DISTRICT, FORSYTH COUNTY, GEORGIA, AND BEING MORE PARTICULARLY DESCRIBED AS FOLLOWS: 

TRACT 1 (V-13) 
 BEGINNING AT A POINT LOCATED AT THE INTERSECTION
OF THE WESTERN RIGHT-OF-WAY OF MCFARLAND ROAD (RIGHT-OF-WAY VARIES) AND THE NORTHERN RIGHT-OF-WAY OF MCGINNIS FERRY ROAD (60 FOOT RIGHT-OF-WAY), AND RUNNING THENCE ALONG THE NORTHERN RIGHT-OF-WAY OF MCGINNIS
FERRY ROAD NORTH 70 DEGREES 39 MINUTES 51 

  

					
		 		  	Loan No. 1015003

 
SECONDS WEST, 419.78 FEET TO A POINT; RUNNING THENCE ALONG AN ARC OF A CURVE TO THE LEFT AN ARC DISTANCE OF 56.37 FEET, HAVING A RADIUS OF 1792.95 FEET, AND BEING SUBTENDED BY A CHORD BEARING FOR
A DISTANCE OF NORTH 71 DEGREES 33 MINUTES 53 SECONDS WEST, 56.36 FEET TO A POINT; THENCE LEAVING THE AFORESAID NORTHERN RIGHT-OF-WAY OF MCGINNIS FERRY ROAD, RUNNING NORTH 02 DEGREES 02 MINUTES 23 SECONDS WEST, A DISTANCE OF 1380.29 FEET TO A POINT;
RUNNING THENCE NORTH 35 DEGREES 04 MINUTES 32 SECONDS EAST, 160.78 FEET TO A POINT; RUNNING THENCE ALONG THE ARC OF A CURVE TO THE RIGHT AN ARC DISTANCE OF 417.28 FEET, HAVING A RADIUS OF 425.97 FEET, AND BEING SUBTENDED BY A CHORD BEARING FOR A
DISTANCE OF NORTH 15 DEGREES 41 MINUTES 37 SECONDS EAST, 400.79 FEET TO A POINT; RUNNING THENCE NORTH 27 DEGREES 08 MINUTES 41 SECONDS EAST, 99.33 FEET TO A POINT ON THE WESTERN RIGHT-OF-WAY LINE OF MCFARLAND ROAD; RUNNING THENCE ALONG SAID
RIGHT-OF-WAY OF MCFARLAND ROAD SOUTH 07 DEGREES 47 MINUTES 15 SECONDS EAST, 535.83 FEET TO A POINT; RUNNING THENCE SOUTH 82 DEGREES 12 MINUTES 45 SECONDS WEST, 20.00 FEET TO A POINT; RUNNING THENCE SOUTH 07 DEGREES 47 MINUTES 15 SECONDS EAST,
1100.00 FEET TO A POINT; RUNNING THENCE SOUTH 82 DEGREES 12 MINUTES 45 SECONDS WEST, 20.00 FEET TO A POINT; RUNNING THENCE SOUTH 07 DEGREES 47 MINUTES 15 SECONDS EAST, 520.70 FEET TO A POINT AT THE INTERSECTION OF THE WESTERN RIGHT-OF-WAY OF
MCFARLAND ROAD AND THE NORTHERN RIGHT-OF-WAY OF MCGINNIS FERRY ROAD, BEING THE POINT OF BEGINNING. 
 SAID TRACT OR PARCEL OF LAND CONTAINS 14.97 ACRES MORE
OR LESS. 
 LESS AND EXCEPT THAT PORTION OF THE ABOVE DESCRIBED PROPERTY CONVEYED TO FORSYTH COUNTY IN THE HEREINAFTER DESCRIBED LESS AND EXCEPT PROPERTY.

 LESS AND EXCEPT THE FOLLOWING TRACTS CONVEYED TO FORSYTH COUNTY BY THAT RIGHT OF WAY DEED RECORDED AT DEED BOOK 1743 PAGE 129, AFORESAID RECORDS: 

PARCEL 1 - TRACT I 
 ALL THAT TRACT OR PARCEL OF LAND
LYING AND BEING IN LAND LOT 1034 OF THE 2ND DISTRICT, 1ST SECTION, FORSYTH COUNTY, GEORGIA AND BEING MORE PARTICULARLY DESCRIBED AS FOLLOWS: 
 BEGINNING AT
POINT RW866, SAID POINT BEING 3.384 METERS LEFT OF MCFARLAND ROAD CONSTRUCTION CENTERLINE STATION 10+009.457; RUNNING THENCE N 73° 02’ 04.5” W A DISTANCE OF 100.000 METERS TO POINT RW3, SAID POINT BEING 8.929 METERS RIGHT OF MCGINNIS
FERRY 
 CONSTRUCTION CENTERLINE STATION 50+289.439; RUNNING THENCE N 73° 09’ 05.2” W A DISTANCE OF 28.954 METERS TO POINT RW874, SAID POINT
BEING 8.929 METERS RIGHT OF MCGINNIS FERRY CONSTRUCTION CENTERLINE STATION 50+318.392; RUNNING THENCE N 71° 52’ 07.2” W A DISTANCE OF 16.176 METERS TO POINT RW1477, SAID POINT BEING 9.655 METERS RIGHT OF MCGINNIS FERRY CONSTRUCTION
CENTERLINE STATION 50+334.135; RUNNING THENCE N 4° 47’ 34.6” W A DISTANCE OF 3.960 METERS TO POINT RW873, SAID POINT BEING 13.400 METERS 

  

					
		 		  	Loan No. 1015003

 
RIGHT OF MCGINNIS FERRY CONSTRUCTION CENTERLINE STATION 50+335.381; RUNNING THENCE ALONG THE ARC OF A CURVE TO THE RIGHT (SAID CURVE HAVING A RADIUS OF 363.400 METERS AND BEING SUBTENDED BY A
CHORD HAVING A CHORD LENGTH OF 17.635 METERS AND A CHORD BEARING OF S 74° 32’ 30.9” E) AN ARC DISTANCE OF 17.637 METERS TO POINT RW228, SAID POINT BEING 13.400 METERS RIGHT OF MCGINNIS FERRY CONSTRUCTION CENTERLINE STATION 50+318.394;
RUNNING THENCE S 73° 09’ 05.6” E A DISTANCE OF 70.251 METERS TO POINT RW99, SAID POINT BEING 13.400 METERS RIGHT OF MCGINNIS FERRY CONSTRUCTION CENTER LINE STATION 50+248.143; RUNNING THENCE N 16° 50’ 54.4” E A DISTANCE
OF 3.600 METERS TO POINT RW100, SAID POINT BEING 17.000 METERS RIGHT OF MCGINNIS FERRY CONSTRUCTION CENTERLINE STATION 50+248.143; RUNNING THENCE S 73° 09’ 07.4” E A DISTANCE OF 29.999 METERS TO POINT RW101, SAID POINT BEING 17.000
METERS RIGHT OF MCGINNIS FERRY CONSTRUCTION CENTERLINE STATION 50+218.144; RUNNING THENCE N 52° 36’ 16.0” E A DISTANCE OF 9.880 METERS TO POINT RW102, SAID POINT BEING 23.138 METERS LEFT OF MCGINNIS FERRY CONSTRUCTION CENTERLINE
STATION 10+029.484; RUNNING THENCE ALONG THE ARC OF A CURVE TO THE LEFT (SAID CURVE HAVING A RADIUS OF 352.000 METERS AND BEING SUBTENDED BY A CHORD HAVING A CHORD LENGTH OF 50.518 METERS AND A CHORD BEARING OF N 4° 20’ 16.3” E) AN ARC
DISTANCE OF 50.562 METERS TO POINT RW231, SAID POINT BEING 23.000 METERS LEFT OF MCGINNIS FERRY CONSTRUCTION CENTERLINE STATION 10+082.704; RUNNING THENCE S 10° 27’ 31.2” E A DISTANCE OF 73.840 METERS BACK TO THE POINT OF BEGINNING.

 SAID RIGHT-OF-WAY CONSISTING OF 1,334.19 SQUARE METERS, MORE OR LESS. 

PARCEL 1 - TRACT 2 
 ALL THAT TRACT OR PARCEL OF LAND
LYING AND BEING IN LAND LOT 982 OF THE 2ND DISTRICT, 1ST SECTION, FORSYTH COUNTY, GEORGIA AND BEING MORE PARTICULARLY DESCRIBED AS FOLLOWS: 
 BEGINNING AT
POINT RW862, SAID POINT BEING 17.096 METERS LEFT OF MCFARLAND ROAD CONSTRUCTION CENTERLINE STATION 10+508.754; RUNNING THENCE S 79° 32’ 42.1” W A DISTANCE OF 5.904 METERS TO POINT RW863, SAID POINT BEING 23.000 METERS LEFT OF MCFARLAND
ROAD CONSTRUCTION CENTERLINE STATION 10+508.751; RUNNING THENCE N 10° 25’ 41.7” W A DISTANCE OF 154.986 METERS TO POINT RW2401, SAID POINT BEING 23.000 METERS LEFT OF MCFARLAND ROAD CONSTRUCTION CENTERLINE STATION 10+663.737; RUNNING
THENCE N 24° 28’ 24.8” E A DISTANCE OF 10.167 METERS TO POINT RW1472, SAID POINT BEING 17.183 METERS LEFT OF MCFARLAND ROAD CONSTRUCTION CENTERLINE STATION 10+672.075; RUNNING THENCE S 10° 27’ 31.2” E A DISTANCE OF
163.321 METERS BACK TO THE POINT OF BEGINNING. 
 SAID RIGHT-OF-WAY CONSISTING OF 932.89 SQUARE METERS, MORE OR LESS. 

Parcel II: 
 “Swap Parcel” 

All that tract or parcel of land lying and being in Land Lots 982 and 1034 of the 2nd Land District, 1st Section, Forsyth County, Georgia, said tract or parcel
of land being more fully shown and designated as TRACT B on a plat of survey prepared by Valentino & Associates, Inc., dated May 12, 2015 (Job #14-083; Drawing/File #14-083), bearing the seal of Glenn A. Valentino, Ga. Registered Land
Surveyor #2528, and being more particularly described as follows: 
 TO FIND THE POINT OF BEGINNING, COMMENCE at a concrete right-of-way (r/w) monument
located at the southwesterly corner of the mitered intersection of the westerly right-of-way line of McFarland Road (variable width public r/w) and the northerly right-of-way line of McGinnis Ferry Road (variable width public r/w); 

THENCE proceeding along said northerly right-of-way line of McGinnis Ferry Road the following courses and distances: 

North 73 degrees 09 minutes 07 seconds West for a distance of 98.42 feet to a 1/2” iron pin set; 

  

					
		 		  	Loan No. 1015003

 THENCE South 16 degrees 50 minutes 54 seconds West for a distance of 11.81 feet to a computed point (said
computed point being witnessed by a concrete r/w monument found 0.06 feet southwest thereof); 
 THENCE North 73 degrees 09 minutes 06 seconds West for a
distance of 230.48 feet to a 1/2” iron pin set; 
 THENCE along a curve to the left having a radius of 1192.25 feet for an arc distance of 59.50 feet
(said arc being subtended by a chord of North 74 degrees 34 minutes 53 seconds West for a distance of 59.50 feet) to a 1/2” iron pin set; 
 THENCE
departing said northerly right-of-way line of McGinnis Ferry Road, North 04 degrees 42 minutes 39 seconds West for a distance of 68.17 feet to a 1/2” iron pin set, said 1/2” iron pin set being the POINT OF BEGINNING. 

THENCE from the POINT OF BEGINNING, North 10 degrees 22 minutes 22 seconds West for a distance of 1095.36 feet to a 1/2” iron pin set; 

THENCE North 48 degrees 02 minutes 10 seconds East for a distance of 1.34 feet to a 1/2” iron pin set; 

THENCE along a curve to the left having a radius of 32.13 feet for an arc distance of 65.71 feet (said arc being subtended by a chord of North 40 degrees 25
minutes 51 seconds East for a distance of 54.84 feet) to a 1/2” iron pin set; 
 THENCE North 08 degrees 48 minutes 06 seconds West for a distance of
31.94 feet to a 1/2” iron pin set; 
 THENCE North 16 degrees 49 minutes 41 seconds East for a distance of 88.99 feet to a 1/2” iron pin set; 

THENCE North 32 degrees 03 minutes 17 seconds East for a distance of 63.04 feet to a 1/2” iron pin set; 

THENCE South 04 degrees 42 minutes 39 seconds East for a distance of 1294.64 feet to a 1/2” iron pin set, said 1/2” iron pin set being the POINT OF
BEGINNING. 
 Said tract or parcel of land contains 1.593 acres or 69,410 square feet. 

PARCELS I AND II ABOVE ALSO BEING THE SAME PROPERTY AS DESCRIBED BELOW: 

All that tract or parcel of land lying and being in Land Lots 963, 982 and 1034 of the 2nd Land District, 1st Section, Forsyth County, Georgia, said tract or
parcel of land being more fully shown and designated on a plat of survey prepared by Valentino & Associates, Inc. (Job #14-083; Drawing/File #14-083), bearing the seal of Glenn A. Valentino, Ga. Registered Land Surveyor #2528, and being
more particularly described, with bearings relative to Grid North, Georgia West Zone, as follows: 
 BEGINNING at a concrete right-of-way (r/w) monument
located at the southwesterly corner of the mitered intersection of the westerly right-of-way line of McFarland Road (variable width public r/w) and the northerly right-of-way line of McGinnis Ferry Road (variable width public r/w). 

THENCE proceeding along said northerly right-of-way line of McGinnis Ferry Road the following courses and distances: 

North 73 degrees 09 minutes 07 seconds West for a distance of 98.42 feet to a 1/2” iron pin set; 

THENCE South 16 degrees 50 minutes 54 seconds West for a distance of 11.81 feet to a computed point (said computed point being witnessed by a concrete r/w
monument found 0.06 feet southwest thereof); 
 THENCE North 73 degrees 09 minutes 06 seconds West for a distance of 230.48 feet to a 1/2” iron pin
set; 

  

					
		 		  	Loan No. 1015003

 THENCE along a curve to the left having a radius of 1192.25 feet for an arc distance of 59.50 feet (said arc
being subtended by a chord of North 74 degrees 34 minutes 53 seconds West for a distance of 59.50 feet) to a 1/2” iron pin set; 
 THENCE departing
said northerly right-of-way line of McGinnis Ferry Road North 04 degrees 42 minutes 39 seconds West for a distance of 68.17 feet to a 1/2” iron pin set; 

THENCE North 10 degrees 22 minutes 22 seconds West for a distance of 1095.36 feet to a 1/2” iron pin set; 

THENCE North 48 degrees 02 minutes 10 seconds East for a distance of 1.34 feet to a 1/2” iron pin set; 

THENCE along a curve to the left having a radius of 32.13 feet for an arc distance of 65.71 feet (said arc being subtended by a chord of North 40 degrees 25
minutes 51 seconds East for a distance of 54.84 feet) to a 1/2” iron pin set; 
 THENCE North 08 degrees 48 minutes 06 seconds West for a distance of
31.94 feet to a 1/2” iron pin set; 
 THENCE North 16 degrees 49 minutes 41 seconds East for a distance of 88.99 feet to a 1/2” iron pin set; 

THENCE North 32 degrees 03 minutes 17 seconds East for a distance of 63.04 feet to a 1/2” iron pin set; 

THENCE North 32 degrees 24 minutes 17 seconds East for a distance of 160.78 feet to a 1/2” iron pin set; 

THENCE along a curve to the right having a radius of 417.28 feet for an arc distance of 418.06 feet (said arc being subtended by a chord of North 13 degrees
01 minutes 21 seconds East for a distance of 400.79 feet) to a 1/2” iron pin set; 
 THENCE North 24 degrees 28 minutes 25 seconds East for a distance
of 65.49 feet to a 1/2” iron pin set on the aforesaid westerly right-of-way line of McFarland Road; 
 THENCE proceeding along said westerly
right-of-way line of McFarland Road the following courses and distances: 
 South 10 degrees 26 minutes 11 seconds East for a distance of 1608.09 feet to a
1/2” iron pin set; 
 THENCE South 79 degrees 32 minutes 29 seconds West for a distance of 20.00 feet to a 1/2” iron pin set; 

THENCE South 10 degrees 27 minutes 31 seconds East for a distance of 278.44 feet to a computed point (said computed point being witnessed by a concrete r/w
monument found 0.25 feet northwest thereof); 
 THENCE along a curve to the right having a radius of 1154.85 feet for an arc distance of 165.88 feet (said
arc being subtended by a chord of South 04 degrees 20 minutes 16 seconds West for a distance of 165.74 feet) to a computed point (said computed point being witnessed by a concrete r/w monument found 0.23 feet northwest thereof); 

THENCE South 52 degrees 36 minutes 16 seconds West for a distance of 32.41 feet to a concrete r/w monument found, said concrete r/w monument found being the
POINT OF BEGINNING. 

  

					
		 		  	Loan No. 1015003

 EXHIBIT B - DOCUMENTS 

 

	1.	Loan Documents. The documents listed below and amendments, modifications and supplements thereto which have received the prior written consent of Lender, together with any documents executed in the future that
are approved by Lender and that recite that they are “Loan Documents” for purposes of this Agreement are collectively referred to herein as the Loan Documents. The documents listed below are each dated of even date herewith unless
stated otherwise. 

  

	 	1.1	This Agreement. 

  

	 	1.2	The Note. 

  

	 	1.3	The Borrowers Cash Management Agreement. 

  

	 	1.4	The Guarantor Cash Management Agreement. 

  

	 	1.5	Indemnity and Contribution Agreement among Borrowers, Guarantor and Lender. 

  

	 	1.6	Deed of Trust with Absolute Assignment of Leases and Rents, Security Agreement and Fixture Filing granted by Redlands DC LP, a Delaware limited partnership, for the benefit of Lender, and to be recorded in the records
of San Bernardino County, California. 

  

	 	1.7	Deed of Trust with Absolute Assignment of Leases and Rents, Security Agreement and Fixture Filing granted by Cajon DC LP, a Delaware limited partnership, for the benefit of Lender, dated and to be recorded in the
records of San Bernardino County, California. 

  

	 	1.8	Mortgage with Absolute Assignment of Leases and Rents, Security Agreement and Fixture Filing granted by Miami DC III LLC, a Delaware limited liability company, and Miami DC III Land LLC, a Delaware limited liability
company, for the benefit of Lender, and to be recorded in the records of Miami-Dade County, Florida. 

  

	 	1.9	Mortgage with Absolute Assignment of Leases and Rents, Security Agreement and Fixture Filing granted by Miami DC IV LLC, a Delaware limited liability company, for the benefit of Lender, and to be recorded in the records
of Miami-Dade County, Florida. 

  

	 	1.10	Mortgage with Absolute Assignment of Leases and Rents, Security Agreement and Fixture Filing granted by Tamarac Commerce Center DC II LLC, a Delaware limited liability company, for the benefit of Lender, and to be
recorded in the records of Broward County, Florida. 

  

	 	1.11	Mortgage with Absolute Assignment of Leases and Rents, Security Agreement and Fixture Filing granted by Tamarac Commerce Center DC III LLC, a Delaware limited liability company, for the benefit of Lender, and to be
recorded in the records of Broward County, Florida. 

  

	 	1.12	Open-End Mortgage, Assignment of Leases and Rents, Security Agreement and Fixture Filing granted by Lehigh Valley Crossing DC I LLC, a Delaware limited liability company, and for the benefit of Lender, and to be
recorded in the records of Lehigh County, Pennsylvania. 

  

	 	1.13	Open-End Mortgage, Assignment of Leases and Rents, Security Agreement and Fixture Filing granted by Lehigh Valley Crossing DC II LLC, a Delaware limited liability company, for the benefit of Lender, and to be recorded
in the records of Lehigh County, Pennsylvania. 

  

					
		 		  	Loan No. 1015003

	 	1.14	Open-End Mortgage, Assignment of Leases and Rents, Security Agreement and Fixture Filing granted by Lehigh Valley Crossing DC III LLC, a Delaware limited liability company, for the benefit of Lender, and to be recorded
in the records of Lehigh County, Pennsylvania. 

  

	 	1.15	Deed to Secure Debt with Absolute Assignment of Leases and Rents, Security Agreement and Fixture Filing granted by Bluegrass DC II LLC, a Delaware limited liability company, for the benefit of Lender, and to be recorded
in the records of Forsyth County, Georgia. 

  

	 	1.16	Assignment of Construction Agreements executed by Bluegrass II DC LLC in favor of Lender. 

  

	 	1.17	Assignment of Construction Agreements executed by Lehigh Valley Crossing II DC LLC in favor of Lender. 

  

	 	1.18	Assignment of Design Professional Agreements and Plans and Specification executed by Bluegrass II DC LLC in favor of Lender. 

  

	 	1.19	Assignment of Design Professional Agreements and Plans and Specification executed by Lehigh Valley Crossing II DC LLC in favor of Lender. 

 

	 	1.20	Subordination and Assignment of Development Management Agreement between Bluegrass DC II LLC and Seefried Industrial Properties. 

  

	 	1.21	Subordination and Assignment of Development Management Agreement among Lehigh Valley Crossing DC I LLC, Lehigh Valley Crossing DC II LLC and Panattoni Development Company, Inc. 

 

	 	1.22	Subordination and Assignment of Property Management Agreement between Redlands DC LP and Cushman & Wakefield of California, Inc. 

 

	 	1.23	Subordination and Assignment of Property Management Agreement between Cajon DC LP and Cushman & Wakefield of California, Inc. 

 

	2.	Other Related Documents (Which Are Not Loan Documents): 

  

	 	2.1	Repayment Guaranty Agreement (“Repayment Guaranty”) executed by Guarantor in favor of Lender. 

  

	 	2.2	Completion Guaranty Agreement (“Completion Guaranty” and collectively with the Repayment Guaranty, “Guaranty”) executed by Guarantor in favor of Lender. 

 

	 	2.3	Hazardous Materials Indemnity Agreement executed by Borrower and Guarantor (collectively, the “Indemnitor”) (the “Indemnity”) in favor of Lender. 

 

	 	2.4	Disbursement Instruction Agreement executed by Borrowers. 

  

					
		 		  	Loan No. 1015003

 EXHIBIT C – LOAN BUDGET 

The Loan Budget set forth herein represents an analysis of the total costs necessary in Borrowers’ estimation to perform Borrowers’ obligations
under the Loan Documents. Column A, “Total Costs”, sets forth Borrowers’ representation of the maximum costs for each Item specified in Column A. Column B “Costs Paid By Borrower Prior to Loan Closing”, sets
forth Borrowers’ representation of costs that Borrower has paid or has caused to be paid from other sources of funds for each Item specified in Column B. Column C, “Remaining Costs” sets forth Borrowers’ representation of
the remaining costs that Borrower deems necessary in Borrowers’ estimation to perform Borrowers’ obligations under the Loan Documents for each Item specified in Column C. Column D, “Borrower’s Equity Contributed Upon Closing
to Fund Estimated Cost Already Incurred In Relation to (C) Remaining Costs” sets forth the amount of equity funded by borrower into the Master Operating Account at closing, which funds shall be used by Borrowers to pay for the Items
specified in Column D prior to disbursement of Loan proceeds for such items (and as further described in the Property Level Budgets attached as Exhibit I). Column E, “Initial Loan Disbursement At Closing” sets forth the Initial
Disbursement being made by Lender at closing. Column F, “Remaining Loan Disbursement Budget”, sets forth Borrowers’ representation of the remaining costs that will be funded by Loan proceeds for each Item specified in Column F.
Unless specified otherwise, all reference to Columns or Items in this Agreement refer to Columns or Items in this Exhibit C. 
 Notwithstanding
anything to the contrary contained herein, the Loan Budget represents an aggregate budget for the Properties, and budgets for each Property are set forth on Exhibit I. 

[THE LOAN BUDGET FOLLOWS THIS COVER PAGE] 

  

					
		 		  	Loan No. 1015003

 [Omitted] 

  

					
		 		  	Loan No. 1015003

 EXHIBIT D - DISBURSEMENT PLAN 

 

	1.	Timing of Disbursement. Unless another provision of this Agreement specifies otherwise, on or about the first (1st) day of each month, or at such other times as Lender may approve or determine more
appropriate, Borrowers shall submit to: 

 Wells Fargo Bank, National Association 

MAC No. N9303-110 
 608 Second
Avenue South, 11th Floor 
 Minneapolis, MN 55402-1916 

Attn: Disbursement Administrator 

Loan No. 1014912 
 Fax No.:
(866) 968-5584 
 a written itemized statement, signed by Borrowers (“Application for Payment”) setting forth: 

 

	 	1.1	a description of the work performed, material supplied and/or costs incurred or due for which disbursement is requested with respect to any line item (“Item”) shown in Column F (“Disbursement
Budget”) of the Financial Requirement Analysis attached as Exhibit C to this Agreement, together with a description indicating the corresponding Item in a Property Level Budget; and 

 

	 	1.2	the total amount incurred, expended and/or due for each requested Item less prior disbursements. 

Each Application for Payment by Borrowers shall constitute a representation and warranty by Borrowers that Borrowers are in compliance with all
the conditions precedent to a disbursement specified in this Agreement. 
 Lender shall disburse funds with five (5) Business Days of
receipt of all of required information from Borrowers which is in form and substance reasonably acceptable to Lender. 
  

	2.	Lender’s Right to Condition Disbursements. Lender shall have the right to condition any disbursement upon Lender’s receipt and approval of the following: 

 

	 	2.1	Lender’s or its agent’s right to inspect the applicable Construction Improvements; 

  

	 	2.2	Lender’s written approval of the applicable Construction Improvements projects or Leasing Commissions; 

  

	 	2.3	the Application for Payment and an itemized requisition for payment of Items 3 through 5 shown in the Disbursement Budget (“Hard Costs”); 

 

	 	2.4	bills, invoices, documents of title, vouchers, statements, payroll records, receipts and any other documents evidencing the total amount expended, incurred or due for any requested Items; 

 

	 	2.5	evidence of Borrowers’ use of a lien release, joint check and voucher system reasonably acceptable to Lender for payments or disbursements to any contractor, subcontractor, materialman, supplier or lien claimant;

  

	 	2.6	architect’s, inspector’s and/or engineer’s periodic certifications of the construction that has been completed and its conformance to the applicable Plans and Specifications and governmental requirements
based upon any such architect’s, inspector’s and/or engineer’s periodic physical inspections of a Property and Construction Improvements; 

  

					
		 		  	Loan No. 1015003

	 	2.7	waivers and releases of any mechanics’ lien, equitable lien claim or other lien claim rights; 

  

	 	2.8	evidence of Borrower’s compliance with the provisions of Article 4 and Section 6.1 of this Agreement. 

  

	 	2.9	Certificate of Substantial Completion from the applicable Contractor and Borrower, if any, prior to the final retention disbursement of Hard Costs for each separate Construction Improvements project, as applicable;

  

	 	2.10	any other document, requirement, evidence or information that Lender may reasonably request under any provision of the Loan Documents and for which Lender will use reasonable efforts to request all additional documents
at the same time; 

  

	 	2.11	evidence that any goods, materials, supplies, fixtures or other work in process for which disbursement is requested have been incorporated into the Improvements; 

 

	 	2.12	in the event any Application for Payment includes the cost of materials stored at a location other than any Property (“Offsite Materials”), such Application for Payment shall include each of the
following: (a) evidence that the Offsite Materials have been purchased by a Borrower, have been segregated from other materials in the facility and have been appropriately marked to indicate such Borrower’s ownership thereof and
Lender’s security interest therein; and (b) evidence that the Offsite Materials are insured as required by this Agreement; and (c) at Lender’s request, a security agreement, financing statement and/or subordination agreement in
form and substance reasonably satisfactory to Lender executed by the supplier of the Offsite Materials, and/or such other persons as Lender determines may have an interest in or claim to the Offsite Materials, together with such other additional
documentation and evidence as Lender may reasonably require to assure itself that it has a perfected first priority lien on the Offsite Materials. 

  

	 	2.13	in the event that any Application for Payment includes the cost of materials stored on a Property (“Onsite Materials”), such Application for Payment shall include each of the following:
(a) evidence that the Onsite Materials have been purchased by a Borrower; (b) evidence that the Onsite Materials are insured as required hereunder; and (c) evidence that the Onsite Materials are stored in an area on such Property for
which adequate security is provided against theft and vandalism; 

  

	 	2.14	Lender shall have received a date-down endorsement or other title report dated within five (5) days of the requested disbursement from the Title Company showing no state of facts objectionable to Lender (including,
without limitation, a showing that title to the Property is vested in a Borrower and that no claim for mechanics’ or materialmen’s liens has been filed against such Property). 

Each Borrower acknowledges that such Borrower’s failure to comply with the above timing may result in disbursement delays and each
Borrower hereby consents to all such delays. 

  

					
		 		  	Loan No. 1015003

 EXHIBIT E – DISBURSEMENT INSTRUCTION AGREEMENT 

[The form of Disbursement Instruction Agreement follows this cover page.] 

  

					
		 		  	Loan No. 1015003

 DISBURSEMENT INSTRUCTION AGREEMENT 

 

	
	 Borrower: REDLANDS DC LP, a Delaware limited partnership, CAJON DC LP, a Delaware limited partnership, MIAMI DC III LLC,
a Delaware limited liability company, MIAMI DC IV LLC, a Delaware limited liability company, MIAMI DC III LAND LLC, a Delaware limited liability company, TAMARAC COMMERCE CENTER DC II LLC, a Delaware limited liability company,
TAMARAC COMMERCE CENTER DC III LLC, a Delaware limited liability company, LEHIGH VALLEY CROSSING DC I LLC, a Delaware limited liability company, LEHIGH VALLEY CROSSING DC II LLC, a Delaware limited liability company, LEHIGH
VALLEY CROSSING DC III LLC, a Delaware limited liability company, BLUEGRASS DC II LLC, a Delaware limited liability company, individually and collectively
  

Guarantor: DC LIQUIDATING ASSETS HOLDCO LLC, a Delaware limited liability company

 
 (Borrower and Guarantor, collectively, “Loan Parties”)

	
	Lender: WELLS FARGO BANK, NATIONAL ASSOCIATION
	
	Loan: Loan number 1015003 made pursuant to that certain Construction Loan Agreement dated as of November 4, 2015 between Borrower and Lender, as amended from time to time (the “Loan Agreement”)
	
	Effective Date: November 4, 2015
	
	 Check applicable box:

  

	 	x	New – This is the first Disbursement Instruction Agreement submitted in connection with the Loan. 

  

	 	 ̈	Replace Previous Agreement – This is a replacement Disbursement Instruction Agreement. All prior instructions submitted in connection with this Loan are cancelled as of the Effective Date set forth above.

 This Agreement must be signed by the Loan Parties and is used for the following purposes: 

 

	 	(1)	to designate an individual or individuals with authority to request disbursements of Loan proceeds, whether at the time of Loan closing/origination or thereafter; 

 

	 	(2)	to designate an individual or individuals with authority to request disbursements of funds from Accounts (as defined in the Terms and Conditions attached to this Agreement), if applicable; and 

 

	 	(3)	to provide Lender with specific instructions for wiring or transferring funds on Loan Parties’ behalf. 

Any of the disbursements, wires or transfers described above is referred to herein as a “Disbursement.” 

Specific dollar amounts for Disbursements must be provided to Lender at the time of the applicable Disbursement in the form of a signed closing statement, an
email instruction or other written communication (each, a “Disbursement Request”) from an applicable Authorized Representative (as defined in the Terms and Conditions attached to this Agreement). 

A new Disbursement Instruction Agreement must be completed and signed by the Loan Parties if (i) all or any portion of a Disbursement is to be
transferred to an account or an entity not described in this Agreement or (ii) Loan Parties wish to add or remove any Authorized Representatives. 

 See the Additional Terms and Conditions attached hereto for additional information and for definitions of
certain capitalized terms used in this Agreement. 

 DELETE THIS PAGE IF NO DISBURSEMENT(S) AT CLOSING/ORIGINATION. 

DELETE THIS HEADER BEFORE SENDING TO BORROWER. 
 WIRE
INSTRUCTIONS RECEIVED FROM THIRD PARTIES MUST BE ATTACHED. 
  

					
	Disbursement of Loan Proceeds at Origination/Closing
	  
 Closing Disbursement Authorizers: Lender is
authorized to accept one or more Disbursement Requests from any of the individuals named below (each, a “Closing Disbursement Authorizer”) to disburse Loan proceeds on or about the date of the Loan origination/closing and to
initiate Disbursements in connection therewith (each, a “Closing Disbursement”):
  

	 	  	 Individual’s Name
	  	 Title

	1.	  		  	
	2.	  		  	
	3.	  		  	
	  
 Describe Restrictions, if any, on the authority of the
Closing Disbursement Authorizers (dollar amount limits, wire/deposit destinations, etc.):
  

DESCRIBE APPLICABLE RESTRICTIONS OR INDICATE “N/A”
  

If there are no restrictions described here, any Closing Disbursement Authorizer may submit a Disbursement Request for all available Loan
proceeds.

 DELETE FOLLOWING SECTION IF NO WIRE TRANSFERS AT ORIGINATION/CLOSING 

 

			
	 Permitted Wire Transfers: Disbursement Requests for the Closing Disbursement(s) to be made by wire transfer must specify
the amount and applicable Receiving Party. Each Receiving Party included in any such Disbursement Request must be listed below. Lender is authorized to use the wire instructions that have been provided directly to Lender by the Receiving Party or
Loan Parties and attached as the Closing Exhibit. All wire instructions must contain the information specified on the Closing Exhibit.
  

	 	  	 Names of Receiving Parties for the Closing Disbursement(s) (may include as many parties as needed; wire
instructions for each Receiving Party must be attached
as the Closing Exhibit)

	1.	  	
	2.	  	
	3.	  	

 DELETE FOLLOWING SECTION IF NO DEPOSITS INTO WFB ACCOUNTS AT ORIGINATION/CLOSING 

ADD LINES FOR ADDITIONAL DEPOSIT ACCOUNT INFORMATION IF NECESSARY 
  

	
	 Direct Deposit: Disbursement Requests for the Closing Disbursement(s) to be deposited into an account at Wells Fargo Bank, N.A. must
specify the amount and applicable account. Each account included in any such Disbursement Request must be listed below.
  

	Name on Deposit Account:
	 Wells Fargo Bank, N.A. Deposit Account Number:

	 Further Credit Information/Instructions:

 DELETE THIS PAGE IF NO DISBURSEMENT(S) SUBSEQUENT TO CLOSING. 

DELETE THIS HEADER BEFORE SENDING TO BORROWER. 
 WIRE
INSTRUCTIONS RECEIVED FROM THIRD PARTIES MUST BE ATTACHED. 
  

					
	 Disbursements of Loan Proceeds Subsequent to Loan Closing/Origination

 

	 Subsequent Disbursement Authorizers: Lender is authorized to accept one or more Disbursement Requests from any of the
individuals named below (each, a “Subsequent Disbursement Authorizer”) to disburse Loan proceeds after the date of the Loan origination/closing and to initiate Disbursements in connection therewith (each, a “Subsequent
Disbursement”):
  

	 	  	 Individual’s Name
	  	 Title

	1.	  		  	
	2.	  		  	
	3.	  		  	
	  
 Describe Restrictions, if any, on the authority of the
Subsequent Disbursement Authorizers (dollar amount limits, wire/deposit destinations, etc.): 
  

DESCRIBE APPLICABLE RESTRICTIONS OR INDICATE “N/A”
  

If there are no restrictions described here, any Subsequent Disbursement Authorizer may submit a Disbursement Request for all available Loan
proceeds.

 DELETE FOLLOWING SECTION IF NO SUBSEQUENT WIRE TRANSFERS ANTICIPATED 

 

			
	 Permitted Wire Transfers: Disbursement Requests for Subsequent Disbursements to be made by wire transfer must specify the
amount and applicable Receiving Party. Each Receiving Party included in any such Disbursement Request must be listed below. Lender is authorized to use the wire instructions that have been provided directly to Lender by the Receiving Party or Loan
Parties and attached as the Subsequent Disbursement Exhibit. All wire instructions must contain the information specified on the Subsequent Disbursement Exhibit.

 

	 	  	 Names of Receiving Parties for Subsequent Disbursements (may include as many parties as needed;
wire instructions for each Receiving Party must be attached
as the Subsequent Disbursement Exhibit)

	1.	  	
	2.	  	
	3.	  	

 DELETE FOLLOWING SECTION IF NO DEPOSITS INTO WFB ACCOUNTS AT ORIGINATION/CLOSING 

ADD LINES FOR ADDITIONAL DEPOSIT ACCOUNT INFORMATION IF NECESSARY 
  

	
	 Direct Deposit: Disbursement Requests for Subsequent Disbursements to be deposited into an account at Wells Fargo Bank, N.A. must
specify the amount and applicable account. Each account included in any such Disbursement Request must be listed below.
  

	Name on Deposit Account:
	Wells Fargo Bank, N.A. Deposit Account Number:
	Further Credit Information/Instructions:

 DELETE THIS PAGE IF NO RESTRICTED ACCOUNTS. 

DELETE THIS HEADER BEFORE SENDING TO BORROWER. 
 WIRE
INSTRUCTIONS RECEIVED FROM THIRD PARTIES MUST BE ATTACHED. 
  

					
	Guarantor Reserve Account Disbursements
	  
 Guarantor Reserve Account Disbursement Authorizers:
Lender is authorized to accept one or more Disbursement Requests from any of the individuals named below (each, a “Guarantor Account Disbursement Authorizer”) to disburse funds from the Guarantor Reserve Account and to initiate
Disbursements in connection therewith (each, a “Guarantor Account Disbursement”):
  

	 	  	 Individual’s Name
	  	 Title

	1.	  		  	
	2.	  		  	
	3.	  		  	
	  
 Describe restrictions, if any, on the authority of the
Guarantor Account Disbursement Authorizers (dollar amount limits, wire/deposit destinations, etc.):
  

DESCRIBE APPLICABLE RESTRICTIONS OR INDICATE “N/A”
  

If there are no restrictions described here, any Guarantor Account Disbursement Authorizer may submit a Disbursement Request for all available
funds.

 DELETE FOLLOWING SECTION IF NO WIRE TRANSFERS FROM ACCOUNT ANTICIPATED 

 

			
	 Permitted Wire Transfers: Disbursement Requests for Guarantor Account Disbursements to be made by wire transfer must
specify the amount and applicable Receiving Party. Each Receiving Party included in any such Disbursement Request must be listed below. Lender is authorized to use the wire instructions that have been provided directly to Lender by the Receiving
Party or Loan Parties and attached as the Account Disbursement Exhibit. All wire instructions must contain the information specified on the Account Disbursement Exhibit.

 

	 	  	 Names of Receiving Parties for Guarantor Account Disbursements (may include as many parties as
needed; wire instructions for each Receiving Party must be
attached as the Account Disbursement Exhibit)

	1.	  	
	2.	  	
	3.	  	

 DELETE FOLLOWING SECTION IF NO DEPOSITS INTO WFB ACCOUNTS AT ORIGINATION/CLOSING 

ADD LINES FOR ADDITIONAL DEPOSIT ACCOUNT INFORMATION IF NECESSARY 
  

	
	 Direct Deposit: Disbursement Requests for Guarantor Account Disbursements to be deposited into an account at Wells Fargo Bank, N.A.
must specify the amount and applicable account. Each account included in any such Disbursement Request must be listed below.
  

	Name on Deposit Account:
	Wells Fargo Bank, N.A. Deposit Account Number:
	Further Credit Information/Instructions:

 Loan Parties acknowledge that all of the information in this Agreement is correct and agrees to the terms and
conditions set forth herein and in the Additional Terms and Conditions on the following page. 
  

					
	“BORROWER”
	
	BLUEGRASS DC II LLC, formerly known as IIT Bluegrass DC II LLC
	LEHIGH VALLEY CROSSING DC I LLC, formerly known as IIT Lehigh Valley Crossing DC I LLC
	LEHIGH VALLEY CROSSING DC II LLC, formerly known as IIT Lehigh Valley Crossing DC II LLC
	LEHIGH VALLEY CROSSING DC III LLC, formerly known as IIT Lehigh Valley Crossing DC III LLC
	MIAMI DC III LLC, formerly known as IIT Miami DC III LLC
	MIAMI DC IV LLC, formerly known as IIT Miami DC IV LLC
	TAMARAC COMMERCE CENTER DC II LLC, formerly known as IIT Tamarac Commerce Center II LLC
	TAMARAC COMMERCE CENTER DC III LLC, formerly known as IIT Tamarac Commerce Center III LLC
	MIAMI DC III LAND LLC, formerly known as IIT Miami DC III Land LLC,
	 each a Delaware limited liability company

		
	By:	 	  

	Name:	 	Lainie P. Minnick
	Title:	 	Senior Vice President, Finance and Treasurer
	
	CAJON DC LP, a Delaware limited partnership, formerly known as IIT Cajon DC LP
		
	By:	 	Cajon DC GP LLC, a Delaware limited liability company, formerly known as IIT Cajon DC GP LLC, its general partner
			
		 	By:	 	  

		 	Name:	 	Lainie P. Minnick
		 	Title:	 	Senior Vice President, Finance and Treasurer
	
	REDLANDS DC LP, a Delaware limited partnership, formerly known as IIT Redlands DC LP
		
	By:	 	Redlands DC GP LLC, a Delaware limited liability company, formerly known as IIT Redlands DC GP LLC, its general partner
			
		 	By:	 	  

		 	Name:	 	Lainie P. Minnick
		 	Title:	 	Senior Vice President, Finance and Treasurer

					
	GUARANTOR
	
	 DC LIQUIDATING ASSETS HOLDCO LLC,

a Delaware limited liability company

		
	By:	 	DC Industrial Liquidating Trust,
		 	a Maryland statutory trust, its managing member
			
		 	By:	 	  

		 	Name:	 	Lainie P. Minnick
		 	Title:	 	Senior Vice President, Finance and Treasurer

 Additional Terms and Conditions to the Disbursement Instruction Agreement 

Definitions. The following capitalized terms shall have the meanings set forth below: 

“Account” means the Accounts and the Master Operating Account, each as such term is defined in the Loan Agreement. 

“Authorized Representative” means any or all of the Closing Disbursement Authorizers, Subsequent Disbursement Authorizers and
Account Disbursement Authorizers, as applicable. 
 “Guarantor Reserve Account” means the “Guarantor Reserve
Account” as such term is defined in the Loan Agreement. 
 “Receiving Bank” means the financial institution where a
Receiving Party maintains its account. 
 “Receiving Party” means the ultimate recipient of funds pursuant to a Disbursement
Request. 
 Capitalized terms used in these Additional Terms and Conditions to Disbursement Instruction Agreement and not otherwise defined herein shall
have the meanings given to such terms in the body of the Agreement. 
 Disbursement Requests. Lender must receive Disbursement Requests in writing.
Verbal requests are not accepted. Disbursement Requests will only be accepted from the applicable Authorized Representatives designated in the Disbursement Instruction Agreement. Disbursement Requests will be processed subject to satisfactory
completion of Lender’s customer verification procedures. Lender is only responsible for making a good faith effort to execute each Disbursement Request and may use agents of its choice to execute Disbursement Requests. Funds disbursed pursuant
to a Disbursement Request may be transmitted directly to the Receiving Bank, or indirectly to the Receiving Bank through another bank, government agency, or other third party that Lender considers to be reasonable. Lender will, in its sole
discretion, determine the funds transfer system and the means by which each Disbursement will be made. Lender may delay or refuse to accept a Disbursement Request if the Disbursement would: (i) violate the terms of this Agreement;
(ii) require use of a bank unacceptable to Lender or prohibited by government authority; (iii) cause Lender to violate any Federal Reserve or other regulatory risk control program or guideline; or (iv) otherwise cause Lender to
violate any applicable law or regulation. 
 Limitation of Liability. Lender shall not be liable to Loan Parties or any other parties for:
(i) errors, acts or failures to act of others, including other entities, banks, communications carriers or clearinghouses, through which Loan Parties’ requested Disbursements may be made or information received or transmitted, and no such
entity shall be deemed an agent of Lender; (ii) any loss, liability or delay caused by fires, earthquakes, wars, civil disturbances, power surges or failures, acts of government, labor disputes, failures in communications networks, legal
constraints or other events beyond Lender’s control; or (iii) any special, consequential, indirect or punitive damages, whether or not (A) any claim for these damages is based on tort or contract or (B) Lender or Loan Parties
knew or should have known the likelihood of these damages in any situation. Lender makes no representations or warranties other than those expressly made in this Agreement. IN NO EVENT WILL LENDER BE LIABLE FOR DAMAGES ARISING DIRECTLY OR INDIRECTLY
IF A DISBURSEMENT REQUEST IS EXECUTED BY LENDER IN GOOD FAITH AND IN ACCORDANCE WITH THE TERMS OF THIS AGREEMENT. 
 Reliance on Information
Provided. Lender is authorized to rely on the information provided by any Loan Party or any Authorized Representative in or in accordance with this Agreement when executing a Disbursement Request until Lender has received a new Agreement signed
by Loan Parties. Loan Parties agree to be bound by any Disbursement Request: (i) authorized or transmitted by Loan Parties; or (ii) made in Loan Parties’ name and accepted by Lender in good faith and in compliance with this Agreement,
even if not properly authorized by Loan Parties. Lender may rely solely (i) on the account number of the Receiving Party, rather than the Receiving Party’s name, and (ii) on the bank routing number of the Receiving Bank, rather than
the Receiving Bank’s name, in executing a Disbursement Request. Lender is not obligated or required in any way to take any actions to detect errors in information provided by Loan Parties or an Authorized Representative. If Lender takes any
actions in an attempt to detect errors in the transmission or content of transfers or requests or takes any actions in an attempt to detect unauthorized Disbursement Requests, Loan Parties agree that, no matter how many times Lender takes these
actions, Lender will not in any situation be liable for failing to take or correctly perform these actions in the future, and such actions shall not become any part of the Disbursement procedures authorized herein, in the Loan Documents, or in any
agreement between Lender and Loan Parties. 
 International Disbursements. A Disbursement Request expressed in US Dollars will be sent in US Dollars,
even if the Receiving Party or Receiving Bank is located outside the United States. Lender will not execute Disbursement Requests expressed in foreign currency unless permitted by the Loan Agreement. 

Errors. Loan Parties agree to notify Lender of any errors in the Disbursement of any funds or of any unauthorized or improperly authorized Disbursement
Requests within fourteen (14) days after Lender’s confirmation to Loan Parties of such Disbursement. If Lender is notified that it did not disburse the full amount requested in a Disbursement Request, Lender’s sole liability will be
to promptly disburse the amount of the stated deficiency. If Lender disburses an amount in excess of the amount requested in a Disbursement Request, Lender will only be liable for such excess amount to the extent that Loan Parties do not receive the
benefit of such amount. 
 Finality of Disbursement Requests. Disbursement Requests will be final and will not be subject to stop payment or recall;
provided that Lender may, at Loan Parties’ request, make an effort to effect a stop payment or recall but will incur no liability whatsoever for its failure or inability to do so. 

 DELETE THIS PAGE IF NOT APPLICABLE 

DELETE THIS HEADER BEFORE SENDING TO BORROWER 
 WIRE INFORMATION
SHOULD BE PRINTED OUT AND ATTACHED TO THIS EXHIBIT – NO NEED TO TRANSCRIBE BELOW 
 CLOSING EXHIBIT 

WIRE INSTRUCTIONS 
 All wire
instructions must contain the following information: 
  

	 	•	 	Transfer/Deposit Funds to (Receiving Party Account Name) 

  

	 	•	 	Receiving Party Deposit Account Number 

  

	 	•	 	Receiving Bank Name, City and State 

  

	 	•	 	Receiving Bank Routing (ABA) Number 

  

	 	•	 	Further identifying information, if applicable (title escrow number, borrower name, loan number, etc.) 

 DELETE THIS PAGE IF NOT APPLICABLE 

DELETE THIS HEADER BEFORE SENDING TO BORROWER 
 WIRE INFORMATION
SHOULD BE PRINTED OUT AND ATTACHED TO THIS EXHIBIT – NO NEED TO TRANSCRIBE BELOW 
 SUBSEQUENT DISBURSEMENT EXHIBIT 

WIRE INSTRUCTIONS 
 All wire
instructions must contain the following information: 
  

	 	•	 	Transfer/Deposit Funds to (Receiving Party Account Name) 

  

	 	•	 	Receiving Party Deposit Account Number 

  

	 	•	 	Receiving Bank Name, City and State 

  

	 	•	 	Receiving Bank Routing (ABA) Number 

  

	 	•	 	Further identifying information, if applicable (title escrow number, borrower name, loan number, etc.) 

 DELETE THIS PAGE IF NOT APPLICABLE 

DELETE THIS HEADER BEFORE SENDING TO BORROWER 
 WIRE INFORMATION
SHOULD BE PRINTED OUT AND ATTACHED TO THIS EXHIBIT – NO NEED TO TRANSCRIBE BELOW 
 ACCOUNT DISBURSEMENT EXHIBIT 

WIRE INSTRUCTIONS 
 All wire
instructions must contain the following information: 
  

	 	•	 	Transfer/Deposit Funds to (Receiving Party Account Name) 

  

	 	•	 	Receiving Party Deposit Account Number 

  

	 	•	 	Receiving Bank Name, City and State 

  

	 	•	 	Receiving Bank Routing (ABA) Number 

  

	 	•	 	Further identifying information, if applicable (title escrow number, borrower name, loan number, etc.) 

 EXHIBIT F – DESIGN PROFESSIONAL’S CONSENT FORM 

[The form of Design Professional’s Consent follows this cover page.] 

  

					
		 		  	Loan No. 1015003

 DESIGN PROFESSIONAL’S CONSENT 

The undersigned design professional (collectively referred to as “Design Professional”) hereby consents to the foregoing Assignment to
which this Design Professional’s Consent (“Consent”) is a part, and acknowledges that there presently exists no unpaid claims due to the Design Professional except as set forth on Schedule 1 attached hereto,
arising out of Design Professional’s preparation and delivery of the Plans and Specifications to Borrower and/or the performance of the Design Professional Agreements described in the Assignment. 

Design Professional agrees that if, at any time, Lender shall become the owner of the Property described in Exhibit A attached hereto, or, pursuant to
Lender’s rights under the Loan Documents, elects to undertake or cause the completion of construction of the Construction Improvements on any portion of the Property, in accordance with the Plans and Specifications, and gives Design
Professional written notice of such election; THEN, so long as Design Professional has received, receives or continues to receive the compensation called for under the Design Professional Agreements, Lender may, at Lender’s option, use and rely
on the Plans and Specifications for the purposes for which they were prepared, and Design Professional will continue to perform Design Professional’s obligations under such Design Professional Agreements for the benefit and account of Lender in
the same manner as if performed for the benefit or account of Borrower in the absence of the Assignment. 
 Design Professional further agrees that, in the
event of a material breach by Borrower of the Design Professional Agreements, or any agreement entered into with Design Professional in connection with the Plans and Specifications, so long as Borrower’s interest in the Design Professional
Agreements and Plans and Specifications is assigned to Lender, Design Professional will give written notice to Lender of such breach at the address shown below. Lender shall have thirty (30) days from the receipt of such written notice of
default to remedy or cure said default provided, if such default is of a nature that it cannot be cured within thirty (30) days, Lender shall have thirty (30) days within which to commence the cure and shall thereafter have such reasonable
period of time to complete such cure as is necessary. Nothing herein shall require Lender to cure said default or to undertake completion of construction of the Improvements. If Lender fails to cure or begin to cure said default during such thirty
(30) day period, Design Professional may pursue termination and any other remedies against Borrower that Design Professional is entitle to under the Design Professional Agreement. 

Design Professional confirms that it/he has no knowledge of any prior assignment(s) of any interest in either the Plans and Specifications and/or the Design
Professional Agreements. Except as otherwise defined herein, the terms used herein shall have the meanings given them in the Assignment. 
 Lender’s
Address: 
 Wells Fargo Bank, National Association 

Commercial Real Estate/ REIT Finance Group (AU#2754) 
 10 S.
Wacker Drive, 32nd Floor 
 Chicago, Illinois 60606 

Attn: Craig Koshkarian, Director 
 Loan No. 1015003 

Executed by Design Professional on
                                        . 

“DESIGN PROFESSIONAL” 

[                    ] 

Design Professional’s Address: 

[                    ] 

[                    ] 

  

					
		 		  	Loan No. 1015003

 EXHIBIT G – CONTRACTOR’S CONSENT FORM 

[The form of Contractor’s Consent follows this cover page.] 

  

					
		 		  	Loan No. 1015003

 CONTRACTOR’S CONSENT 

The undersigned (“Contractor”) hereby consents to the foregoing Assignment of Construction Agreements
(“Assignment”), of which this Contractor’s Consent (“Consent”) is a part. 
  

	A.	Contractor and [                    ] have entered into the following Construction Agreements:
[                    ]. 

  

	B.	Contractor agrees that if, at any time, Lender shall become the owner of the Property described in Exhibit A attached hereto, or, pursuant to its rights under the Loan Documents, elects to undertake or cause the
completion of construction of the Construction Improvements on any portion of the Property, and gives Contractor written notice of such election; THEN, so long as the Contractor has received, receives and continues to receive the compensation called
for under the Construction Agreements to which Contractor is a party, Contractor shall continue to perform its obligations under such Construction Agreements in accordance with the terms thereof. 

 

	C.	Contractor further agrees that, in the event of a breach by Borrower of the Construction Agreements, so long as Borrower’s interest in the Construction Agreements is assigned to Lender, Contractor will give written
notice to Lender at the address shown below of such breach. Lender shall have thirty (30) days from the receipt of such written notice of default to remedy or cure said default provided, if such default is of a nature that it cannot be cured
within thirty (30) days, Lender shall have thirty (30) days within which to commence the cure and shall thereafter have such reasonable period of time to complete such cure as is necessary. Nothing herein shall require Lender to cure said
default or to undertake completion of construction of the Construction Improvements. 

  

	D.	Contractor further agrees that, except with the prior written approval of Lender (such approval not to be unreasonably withheld, conditioned or delayed), Contractor shall not perform any construction work on the
Property pursuant to any change in the Plans and Specifications as defined in the Construction Agreements where such change: (a) would constitute a material change in the building material or equipment specifications, the architectural or
structural design, value, architecture or quality of any of the Improvements as defined in the Construction Agreements; or (b) would result in an increase in any item of construction cost in excess of the greater of (i) $100,000 or
(ii) five percent (5%) of the total construction hard costs for the applicable Construction Improvements for all such changes in such items of construction cost; or (c) would affect the structural integrity, quality of building
material or equipment or overall efficiency of operating systems or utility systems of the improvements. The liens of the Security Instrument therein shall have priority over any claim of lien of Contractor arising out of or in any way connected
with any construction work performed by Contractor on the Property pursuant to any change in the Plans and Specifications not approved by Lender where Lender’s approval is required under this Consent. Lender may periodically inspect and copy,
at reasonable times, the books, records and accounting data of Contractor relating to the construction of the Improvements. 

  

	E.	Finally, Contractor shall use money disbursed to or otherwise received by Contractor from or on account of Borrower in connection with the construction of the Improvements solely for the payment of costs incurred in the
construction of the Improvements, including Contractor’s fees, and for no other purpose, until all bills, claims and demands for such costs have been paid in full. 

Contractor warrants and represents that it/he has no knowledge of any prior assignment(s) of any interest in the Construction Agreements to which such
Contractor is a party. Except as otherwise defined herein, the terms used herein shall have the meanings given them in the Assignment. 

  

					
		 		  	Loan No. 1015003

 Lender’s Address: 

Wells Fargo Bank, National Association 
 Commercial Real Estate/
REIT Finance Group (AU#2754) 
 10 S. Wacker Drive, 32nd Floor 

Chicago, Illinois 60606 
 Attn: Craig Koshkarian, Director

 Loan No. 1015003 
 Executed by Contractor on
                                        . 

“CONTRACTOR “ 

[            ] 

Contractor’s Address: 

[                    ] 

[                    ] 

  

					
		 		  	Loan No. 1015003

 EXHIBIT H – OPTION TO EXTEND REQUEST LETTER FROM BORROWER 

[The Option to Extend Request Letter from Borrower follows this cover page.] 

  

					
		 		  	Loan No. 1015003

 NOTE: MUST PRINT ON BORROWER LETTERHEAD 

            , 20     

WELLS FARGO BANK, NATIONAL ASSOCIATION 
 1800 Century Park East,
Suite 1200 
 Los Angeles, California 90067 
 Attn: Kevin
Stacker 
  

	 	RE:	Loan No. 1015003 (“Loan”) 

 Pursuant to the terms of the Construction
Loan Agreement dated November 4, 2015 (“Loan Agreement”), REDLANDS DC LP, a Delaware limited partnership, CAJON DC LP, a Delaware limited partnership, MIAMI DC III LLC, a Delaware limited liability company,
MIAMI DC IV LLC, a Delaware limited liability company, MIAMI DC III LAND LLC, a Delaware limited liability company, TAMARAC COMMERCE CENTER DC II LLC, a Delaware limited liability company, TAMARAC COMMERCE CENTER DC III
LLC, a Delaware limited liability company, LEHIGH VALLEY CROSSING DC I LLC, a Delaware limited liability company, LEHIGH VALLEY CROSSING DC II LLC, a Delaware limited liability company, LEHIGH VALLEY CROSSING DC III LLC, a
Delaware limited liability company, BLUEGRASS DC II LLC, a Delaware limited liability company (collectively, “Borrower”), hereby exercise Borrowers’ option to extend the maturity date of the Loan described therein from
November 3, 2017 to November 3, 2018. Borrowers hereby certify that no Default has occurred and is continuing. Borrowers further certify that they shall satisfy all conditions precedent for such extension listed in the Loan Agreement.

 All capitalized terms used herein, which are not defined herein, shall have the meanings given to them in the Loan Agreement. 

[Remainder of Page Left Intentionally Blank] 

  

					
		 		  	Loan No. 1015003

 
					
	“BORROWER”
	
	BLUEGRASS DC II LLC, formerly known as IIT Bluegrass DC II LLC
	LEHIGH VALLEY CROSSING DC I LLC, formerly known as IIT Lehigh Valley Crossing DC I LLC
	LEHIGH VALLEY CROSSING DC II LLC, formerly known as IIT Lehigh Valley Crossing DC II LLC
	LEHIGH VALLEY CROSSING DC III LLC, formerly known as IIT Lehigh Valley Crossing DC III LLC
	MIAMI DC III LLC, formerly known as IIT Miami DC III LLC
	MIAMI DC IV LLC, formerly known as IIT Miami DC IV LLC
	TAMARAC COMMERCE CENTER DC II LLC, formerly known as IIT Tamarac Commerce Center II LLC
	TAMARAC COMMERCE CENTER DC III LLC, formerly known as IIT Tamarac Commerce Center III LLC
	MIAMI DC III LAND LLC, formerly known as IIT Miami DC III Land LLC, 
	each a Delaware limited liability company
		
	By:	 	  

	Name:	 	  

	Title:	 	  

	
	CAJON DC LP, a Delaware limited partnership, formerly known as IIT Cajon DC LP
		
	By:	 	Cajon DC GP LLC, a Delaware limited liability company, formerly known as IIT Cajon DC GP LLC, its general partner
			
		 	By:	 	  

		 	Name:	 	  

		 	Title:	 	  

	
	REDLANDS DC LP, a Delaware limited partnership, formerly known as IIT Redlands DC LP
		
	By:	 	Redlands DC GP LLC, a Delaware limited liability company, formerly known as IIT Redlands DC GP LLC, its general partner
			
		 	By:	 	  

		 	Name:	 	  

		 	Title:	 	  

  

					
		 		  	Loan No. 1015003

 EXHIBIT I – PROPERTY LEVEL BUDGETS 

[Omitted] 

  

					
		 		  	Loan No. 1015003

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00251-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00251-of-00352.parquet"}]]