Document:

Unassociated Document

 

EXHIBIT 10.8

 

AMENDED AND RESTATED LEASE AGREEMENT

WYNDCREST DD FLORIDA, INC.

This Amended and Restated Capital Lease Agreement (“Lease”), dated as of April 8th, 2010 (the “Commencement Date”), is made by and between City of Port St. Lucie, a Florida municipal corporation (“City”), by and through its City Council (the “Council”), and Wyndcrest DD Florida, Inc., a corporation organized under the laws of the State of Florida (“WDDF”).

WITNESSETH:

WHEREAS, City and WDDF have entered into that certain Grant Agreement, dated as of November 25, 2009, as amended (the “City Grant Agreement”), which provides, among other things, that City will lease to WDDF that certain real property more particularly described in Exhibit A, which consists of approximately fifteen acres of land (the “Site”), and lease to WDDF (i) the Site and a building located on the Site containing approximately 150,000 square feet (the “Permanent Facilities”), and (ii) up to Ten Million Dollars in equipment (the “Equipment”), all as more particularly described in the City Grant Agreement.

WHEREAS, the City entered into a Lease Agreement with WDDF on or about January 8, 2010;and

WHEREAS, the City and WDDF desire to amend and restate the Lease Agreement to incorporate certain financial terms and conditions, and to modify other provisions of the Lease: and

WHEREAS, the City Grant Agreement provides for up to Ten Million Dollars $10,000,000.00 in equipment (“Equipment”), said Equipment shall be provided or acquired during the construction of the Permanent Facilities; and

WHEREAS, the development of the Permanent Facilities will be funded through the issuance of debt instruments and/or bonds through the City; and

WHEREAS, the debt service including principal, interest and all costs associated with the debt instruments and bonds for the Permanent Facilities to be issued by the City pursuant to a Trust Indenture between the City and the Trustee named therein (the “Indenture”) shall be paid by WDDF through lease pajmients, in amounts sufficient to cover the cost of financing; and

WHEREAS, the City has assigned its rights to receive Lease Payments as such term is defined in the Indenture and its right to collect and enforce such Lease Payments by WDDF pursuant to the Indenture and an Assignment Agreement dated as of April 1, 2010, between the City and the Trustee.

 

	
JOSEPH E. SMITH, CLERK OF THE CIRCUIT COURT

	
SAINT LUICE COUNTY

	FILE # 3462143 04/13/2010 AT 04:11 PM
	
OR BOOK 3187 PAGE 806 - 835 Doc Type: AGR

	
RECORDING: $256.50

 

  

 

  

 

NOW, THEREFORE, in consideration of the mutual covenants and agreements contained in this Lease, and intending to be legally bound, City and WDDF hereby agree as follows:

ARTICLE 1

DEFINITIONS

1.1Definitions.  All terms used in this lease, which are defined in the City Grant Agreement shall have the same meanings herein as therein. All terms used in this Lease, which are not otherwise defined herein, but are defined in the Indenture shall have the same meanings herein as therein.

1.2Rent Commencement Date.  Rent Commencement Date shall be the date of issuance of the final certificate of occupancy by the City, which shall be the rent start date.

1.3Interpretation.  Whenever used in this Lease, except as otherwise expressly provided or unless the context otherwise requires, any noun or pronoun shall be deemed to include the plural as well as the singular and to cover all genders. Whenever used in this Lease, unless otherwise specified, the terms “hereof,” “herein,” “hereunder” and similar terms refer to this Lease as a whole, and references herein to Sections refer to specified sections of this Lease. The term “including” when used herein shall be deemed to mean “including, without limitation” and “including, but not limited to.” All Exhibits attached hereto are incorporated herein by reference.

ARTICLE 2

BASIC LEASE PROVISIONS

2.1Term of Lease.  The tenn of this Lease shall commence upon execution of this Agreement. The initial term of the Lease shall only be for the vacant ground during construction of the Permanent Facilities.

Upon issuance of the Certificate of Occupancy, the rent commencement date shall start. The term of the Lease shall run twenty years firom the rent commencement date, or until all debt associated with the issuance of debt instruments and/or bonds by the City for this project shall be paid in full.

2.2Description of Leased Property.  Subject to the terms and conditions of this Lease and the City Grant Agreement, City hereby leases to WDDF, and WDDF rentsfi-omCity, the Site as more particularly described in the attached Exhibit “A”, the Equipment and the Permanent Facilities (collectively, the “Leased Property”).

The City shall receive a full accounting/inventory of all Equipment acquired with the Ten Million dollar equipment fund contained within the debt financing for the leased property so that the City may file a UCC-1, to perfect the City’s security interest in said assets. The UCC-1 statement shall be filed with the Secretary of State. The full accounting/inventory shall be provided at the time of issuance of the certificate of occupancy. Ownership of all equipment shall be retained by the City during the term of this lease.

 

  

Page 2 of 23

  

 

2.3Annual Rent.  WDDF shall pay the City an annual rent sufficient to cover the debt service cost, the cost of capitalized interest, the cost of the reserve debt fund, and all other costs associated with the issuance of debt instruments and/or bonds issued for this Project by the City. The debt service schedule is attached as Exhibit “B”. The annual rent payment calculation estimate is based upon the annual debt service schedule. The first rent payment shall be due from WDDF upon issuance of the certificate of occupancy, but no later than August 1, 2012, and annually thereafter on the first Business Day of such month, without notice or demand from the City. All Base Rent provided in this Section shall be paid by WDDF directly to the Trustee on behalf of the City.

  Pursuant to Florida Statutes, Section 159.30(i)(e), WDDF’s obligation to pay rent shall not be subject to cancellation, termination, or abatement by the Lessee until such payment of the bonds, or provision for such payment is made.

2.4Security Payment.WDDF shall pay a security payment annually in addition to the rent payment to the City. The security payment shall be equal to 1/12 the annual rent payments. Said payment shall be made until one year’s rent payment has been accrued as a security rent payment. WDDF’s obligation to pay the annual security payment shall cease upon the accrual by the City of an amount equal to the annual rent. The City shall maintain the security payment until the debt instruments/bonds are paid in full.

The City may use the security payment to pay any items which are the responsibility of WDDF, but not paid by WDDF, including but not limited to taxes, assessments and other fees including the payment of unreimbursed deposits by the City to replenish the Reserve Fund. In the event the City uses the security payment to pay any items which are the responsibility of WDDF, but not paid by WDDF, including but not limited to taxes, assessments and other fees and unreimbursed deposits by the City to the Reserve Fund, WDDF shall be required to continue making security payments until one year’s annual rent is accrued. The security payment shall be paid upon issuance of the certificate of occupancy and annually thereafter, without notice or demand from the City. Upon termination of this lease, the annual security payments shall be used to pay any amounts then due and outstanding to the City by WDDF. If there are excess funds after payment of all outstanding items, any remaining balance, shall be paid to WDDF within sixty (60) days following the termination of this Lease.

2.5Additional Rent.WDDF shall pay to the City the cost of insurance premiums, taxes, assessments, costs and fees paid for by the City, for which costs and fees are the responsibility of WDDF, but where said costs and fees are advanced by the City. In addition, any costs associated with the bonds as provided in the Indenture, including but not limited to the fees and costs of the Trustee, the Credit Facility Issuer, if any, costs of Ordinary Expenses and/or Extraordinary Expenses, the Rebate Amount, market value deficiencies in the Reserve Fund, and any amounts deposited by the City in the Reserve Fund pursuant to the Covenant, shall be paid by WDDF as Additional Rent directly to the Trustee for disbursement under the Indenture. Any costs contained herein, shall be paid by WDDF to the City or Trustee, as applicable within 30 days receipt of notice from the City or Trustee, as applicable. The City may deduct any costs contained herein from the security payment should WDDF fail to make the payments within 30 days.

 

  

Page 3 of 23

  

 

2.6     “Triple Net”.  This Lease shall be deemed to be “triple net” without cost or expense to City of any nature whatsoever relating to the Leased Property, including, without limitation, those relating to taxes, if any, insurance, repair, maintenance, use, care or operation.

2.7     Taxes and Assessments.  WDDF shall pay all sales, use or rent taxes assessed by any governmental authority against the Basic Rent, if any, even if such tax is intended to be imposed by City. WDDF shall pay before delinquency all ad valorem and non-ad valorem taxes and assessments, whether general or special and all tangible or intangible personal property taxes and assessments of any kind or nature and any and all taxes and other charges that may be levied by any governmental authority against the Leased Property, WDDF’s leasehold interest in the Leased Property, WDDF’s leasehold improvements to or personal property located on the Leased Property, if this Lease or WDDF’s use of the Leased Property renders the Leased Property subject to same. WDDF shall have the right to contest the amount or validity of any tax or assessment payable by it by appropriate legal proceedings; provided, however, that no such right shall be deemed or construed to relieve, modify or extend WDDF’s covenant to pay any such tax or assessment (unless such legal proceedings operate to prevent the collection of the tax or assessment). The City agrees to cooperate with WDDF in obtaining waivers of ad valorem and non ad valorem real estate taxes from tiie City and from other jurisdictions, taxing authorities and agencies. The City also agrees that no impact fees will be charged by the City.

2.8Quiet Eajoyment.  City covenants that, subject to the terms and provisions hereof, WDDF shall and may peaceably and quietly have, hold and enjoy the Leased Property and all parts thereof for the term hereby granted without hindrance or interruption by City or any other person claiming by, through or under City.

2.9Deilverv of Possession of Site.  Upon issuance of the Certificate of Occupancy, the City shall deliver possession of the Site, the Permanent Facilities, and all equipment contained therein to WDDF, WDDF and its officers, employees, consultants, attorneys and/or other authorized representatives shall have the right to copies of all records of the City related to surveys, environmental assessment reports and other information concerning the condition of the Site, for the purposes of inspection.

2.10   Representations and Warranties of City.  As a material inducement to WDDF to enter into this Lease and to consummate the transactions contemplated hereby, City hereby represents and warrants to WDDF, as of the Commencement Date, as follows:

(a)      City is a Florida municipal corporation, which is located in St. Lucie County.

(b)City has all requisite power and authority to execute, deliver and perform this Lease.

(c)This Lease has been duly authorized by all necessary action of the City Council, executed and delivered by City and constitutes a valid and binding agreement of City, enforceable against City in accordance with its terms, except as such enforcement may be limited by bankruptcy, insolvency, reorganization, moratorium or similar laws affecting enforcement of creditors’ rights generally and except as such enforcement is subject to general principles of equity (whether in a proceeding in equity or at law).

 

  

Page 4 of 23

  

 

(d)Neither the (i) authorization, execution and delivery of this Lease; (ii) undertaking of any of the obligations set forth in this Lease by City; nor (iii) obligations imposed or the rights granted to WDDF pursuant to this Lease, confliet with, result in a breach or violation of, or constitute a default under (A) the City’s charter, code of ordinances, or administrative code, (B) any contract, indenture, mortgage, deed of trust, loan agreement, credit agreement, note, lease or other agreement or instrument to which City is a party, or (C) any statute, rule or regulation or any judgment, order or decree of any governmental authority, court or arbitrator applicable to City.

(e)The authorization, execution, delivery and performance of this Lease by the City do not require the consent, approval, authorization, order, registration or qualification of, or filing with, any governmental authority, court or arbitrator having jurisdiction over the City or its assets or properties.

2.11   Tax Covenants

(a)       Special Definitions. When used in this Section, the following terms have the following meanings:

“Computation Date”  has the meaning  set forth  in  section  1.148-(b) of the Tax Regulations.

“Gross Proceeds” means any proceeds, as defined in section 1.148-l(b) of the Tax Regulations (referring to sale, investment and transferred proceeds), and any replacement proceeds, as defined in section 148-l(c) of the Tax Regulations of the Bonds.

“Nonpurpose Investments” means any investment property, as defined in Section 148(b) of the Code, in which Gross Proceeds of the Bonds are invested and that is not acquired to carry out the governmental purpose of the Bonds.

“Investment”  has  the  meaning  set  forth  in  section   1.148-l(b)  of  the  Tax Regulations.

“Rebate Amount”  has  the  meaning  set  forth  in  section  1.148-l(b)  of  the  Tax Regulations.

“Recovery Zone Facility Bonds “ means Recovery Zone Facility Bonds within the meaning of Section 1400U-3(b) o the Code.

“Tax Regulations” means the United States Treasury Regulations promulgated pursuant to sections 103 and 141 through 150 of the Code.

“Yield” of

(i)           any Investment has the meaning set forth in section 1.148-5 of the Tax Regulations; and

(ii)           any Recovery Zone Facility Bonds has the meaning set forth in section 1.148-4 of the Tax Regulations.

 

  

Page 5 of 23

  

 

(b)           Recoveiy Zone Facility Bonds. The representations and covenants in this Section 2.11 and Section 6.05 of the Indenture apply only to Bonds of a series issued and sold as Recovery Zone Facility Bonds, such as the Series 201 OB Bonds.

WDDF further covenants that (i) it will take or cause to be taken such actions that may be required of it for the Bonds to qualify and remain qualified as Recovery Zone Facility Bonds, (ii) WDDF will not take or authorize to he taken any actions that would adversely affect the status of the Bonds as Recovery Zone Facility Bonds, and (iii) WDDF, or persons acting for it, will, among other acts of compliance, (A) apply the Gross Proceeds of the Bonds to the governmental purpose of the borrowing in such manner and to such extent as may he necessary so that the Bonds will qualify as Recovery Zone Facility Bonds, (B) restrict the Yield on Investments of Gross Proceeds, (C) make timely and adequate payments to the federal government, (D) maintain books and records and make calculations and reports and (E) refrain from certain uses of Gross Proceeds, and, as applicable, of property financed with such Gross Proceeds, all in such manner and to the extent necessary to assure that the Bonds are and remain Recovery Zone Facility Bonds.

(c)           Not to Cause Interest to Become Taxable. WDDF shall not use, permit the use of, or omit to use Gross Proceeds or any other amounts (or any property the acquisition, construction or improvement of which is to be financed directly or indirectly with Gross Proceeds) in a manner that if made or omitted, respectively, would cause the interest or any of the Bonds to become includable in the gross income of the owner thereof for federal income tax purposes. Without limiting the generality of the foregoing, unless and until WDDF receives a written opinion of Bond Counsel to the effect that failure to comply with such covenant will not adversely affect the exemption from federal income tax of the interest on any Recovery Zone Facility Bond, WDDF or the City, as the case may be, shall comply with each of the specific covenants in this Section 2.11 and Section 6.05 of the Indenture.

(d)           Not to Invest Higher Yield. Except as would not cause any Bond to become an “arbitrage bond” within the meaning of section 148 of the Code and Tax Regulations and rulings thereunder, WDDF shall not at any time prior to the final maturity of the Bonds directly or indirectly invest Gross Proceeds in any investment if as a result of such investment the Yield of any Investment acquired with Gross Proceeds of an issue of Bonds, whether then held or previously disposed of, would materially exceed the Yield of such Bonds within the meaning of said section 148.

(e)            Not federally Guaranteed. Except to the extent permitted by section 149(b) of the Code and the Tax Regulations and rulings thereunder, WDDF shall not take or omit to take any action that would cause any Bond to be “federally guaranteed” within the meaning of section 149(b) of the Code and the Tax Regulations and rulings thereunder.

 

(f)             Bonds Not Hedge Bonds.

(i)           WDDF represents that no Bonds issued hereunder will become “hedge bonds” within the meaning of section 149(g) of the Code.

(ii)           Without limitation of paragraph (i) above, on the date of issuance of the Bonds WDDF will reasonably expect that at least 85% of the spendable proceeds of the Bonds will be expended within the three-year period commencing on the date of issuance, and WDDF covenants that at no time will more than 50% of the proceeds of the Bonds be invested in Nonpurpose Investments having a substantially guaranteed Yield for a period of four years or more.

 

  

Page 6 of 23

  

 

(g)           Rebate Fund.

(i)           In addition to the other funds and accounts created pursuant to the Indenture, the Trustee will establish and maintain a fund separate from any other fund or account established and maintained under the Indenture designated the “Rebate Fund” (the “Rebate Fund”). Within the Rebate Fund, the Trustee will maintain such accounts or subaccounts as are specified in a written request of the City to the Trustee. The Trustee will deposit moneys in the Rebate Fund pursuant to a written request of the City. Subject to the transfer provisions provided in subparagraph (v) below, all money at any time deposited in the Rebate Fund will be held by the Trustee in trust, to the extent required to satisfy the Rebate Amount, for payment to the federal government of the United States of America, and none of the City, WDDF, the Trustee or the Owner of any Bond shall have any right in or claim to such money. All amounts deposited into or on deposit in the Rebate Fund shall be governed by Section 2.11, Section 6.05 of the Indenture and by the Tax Certificate (which is incorporated herein by reference). The Trustee will be deemed conclusively to have complied with the provisions of Section 6.05 and the Tax Certificate if it follows the written request of the City, including supplying all necessary information requested by the City, and except as otherwise expressly provided herein, shall not be required to take any actions hereunder in the absence of written directions by the City, and shall have no liability or responsibility to enforce compliance by the City with the terms of the Tax Certificate or this Section. The Trustee agrees to comply with all written requests of the City given pursuant to the Tax Certificate.

 

(ii)           Upon a written request of the City, an amount will be deposited into the Rebate Fund by the Trustee from deposits by the City or WDDF, if and to the extent required, so that the balance of the amount on deposit thereto shall be equal to the Rebate Amount. The City will provide the Trustee with written evidence that the computation of the Rebate Amount has been made.

 

(iii)           The Trustee shall have no obligation to rebate any amounts required to be rebated pursuant to the Indenture, other than from moneys held in the funds and accounts created therein or from other moneys provided to it by the City or WDDF.

 

(iv)           The Trustee will invest all amounts held in the Rebate Fund in Permitted Investments as directed by a written request of the City. Money, including investment earnings, shall not be transferred from the Rebate Fund except as provided in subparagraph (v) below.

 

(v)           Upon receipt of a written request of the City, the Trustee will remit part or all the amounts in the Rebate Fund to the United States of America, as so directed. In addition, if the City so directs, the Trustee will deposit moneys into or transfer money out of the Rebate Fund from or into such accounts or fund as directed by the written request of the City. At the written direction of the City, any funds remaining in the Rebate Fund in excess of the Rebate Amount as of the end of any Bond Yecir shall be transferred pro rata based on the aggregate principal amount of Outstanding Bonds of a Series to the Interest Accounts of the Bond Funds.

 

  

Page 7 of 23

  

 

(vi)           Notwithstanding any other provision hereof, including, in particular, Article X of the Indenture, the obligation to remit the Rebate Amount to the United States and to comply with all other requirements of the indenture and the Tax Certificate shall survive the defeasance or payment in full of the Bonds.

(h)  Rebate of Arbitrage Profits. Excepts to the extent otherwise provided in section 148(f) of the Code and the Tax Regulations and rulings thereunder:

(i)           The City and WDDF, each as applicable, shall account for all Gross Proceeds (including all receipts, expenditures and investments thereof) on their book of account separately and apart from all other funds (and receipts, expenditures and investments thereof) and shall retain all records of accounting for at least three years after the day on which the last of the Bonds is discharged. However, to the extent permitted by law, the City or WDDF may commingle Gross Proceeds of the Bonds with their other money, provided that the City or WDDF, as applicable, separately accounts for each receipt and expenditure of Gross Proceeds and the investments acquired therewith.

 

(ii)Not less frequently than each Computation Date, the City shall calculate the Rebate Amount with respect to each Series of Bonds in accordance with rules set forth in section 148(f) of the Code and Tax Regulation and rulings thereunder. The Trustee may rely conclusively upon the City’s determinations, calculations and certifications required by this Section. The Trustee will have no responsibility to independently make any calculation or determination or to review or City’s calculations hereunder. The City shall maintain a copy of the calculations with its official transcripts of proceedings relating to the issuance of the Bonds until three years after the final Computation Date.

 

(iii)In order to assure the excludability of the interest on the Bonds from the gross income of the owners thereof for federal income tax purposes, the City and WDDF, jointly and severally but without duplication, shall deposit in the Rebate Fund and cause the Trustee to pay to the United States the amount that when added to the future value of previous rebate payments made for the Bonds equals (A) in the case of a Final Computation Date as defined in section 1.148-3 (e)(2) of the Tax Regulations, one hundred percent (100%) of the Rebate Amount on such date; and (B) in the case of any other Computation Date, ninety percent (90%) of the Rebate Amount on such date. In all cases, such rebate payments shall be made by the City or WDDF (or by the Trustee at the direction of the City from amounts on deposit in the Rebate Fund) at that times and in the amounts as are or may be required by section 148(f) of the Code and the Tax Regulations and rulings thereunder, and shall be accompanied by Form 8038-T or such other forms and information as is or may be required by section 148(f) of the Code and the Tax Regulations and rulings thereunder for execution and filing by the City.

 

(iv)The City and WDDF shall exercise reasonable diligence to assure that no errors are made in the calculations and payments required by paragraphs (i) and (ii) above, and if an error is made, to discover and promptly correct such error within a reasonable amount of time thereafter (and in all events within one hundred eighty (180) days after discovery of the error), including payment to the United States of any additional Rebate Amount owed to it, interest thereon, and any penalty imposed under section 1.148-3(h) or other provision of the Tax Regulations.

 

  

Page 8 of 23

  

 

(i)             Not to Divert Arbitrage Profits. Except to the extent permitted by section 148 of the Code and Tax Regulations and rulings thereunder, the City and WDDF shall not, at any time prior to the final maturity of the Bonds, enter into any transaction that reduces the amount required to be paid to the United States pursuant to subsection (h) and (i) of Section 6.05 of the Indenture because such transaction results in a smaller profit or a larger loss than would have resulted if the transaction had been at arm’s length and had the Yield not been relevant to either party.

2.12         Payment of Taxes and Compliance with Govemmental Regulations.  WDDF will pay and discharge or cause to be paid and discharged all applicable taxes, assessments and other govemmental charges that may be levied, assessed or charged upon the Project or any part thereof or upon the Lease Payments or any part thereof promptly as an when the same shall become due and payable. WDDF will duly observe and conform with all valid applicable regulations and requirements of any governmental authority relative to the use of the Project or any part thereof, but WDDF shall not be required to comply with any such regulations or requirements so long as the application or the validity thereof shall be contested in good faith.

 

2.13         Insurance Proceeds and Condemnation Awards.  The City and WDDF agree that the Trustee as provided in Section 6.07 of_the Indenture shall receive all moneys which may become due and payable under any insurance policies obtained pursuant to Section 4.5 hereof (other than worker’s compensation insurance required hereunder) and pursuant to any condemnation awards in a separate fund to be established and maintained by the Trustee and designated the “Insurance Proceeds and Condemnation Awards Fund,” and shall apply the proceeds of such insurance as provided in the Indenture. The Trustee will permit withdrawals of said proceeds from time to time upon receiving the Order of Disbursement of the City, stating that the City or WDDF has expended moneys or incurred liabilities in an amount equal to the amount therein requested to be paid over to it for the purpose of repair, reconstruction or replacement, and specifying the items for which such moneys were expended, or such liabilities were incurred, as provided in Section 6.07 of the Indenture.

 

2.14         Accounting Records and Reports.  WDDF will keep or cause to be kept proper books of record and accounts in which complete and correct entries shall be made of all transactions relating to the receipts, disbursements, allocation and application of the Revenues, and such books shall be available for inspection by the City or the Trustee (who shall have no duty to inspect), at reasonable hours and under reasonable conditions. WDDF shall also keep or cause to be kept such other information as is required under the Tax Certificate. The Trustee shall not have any responsibility to review such financial statements or information it receives, but shall retain such information solely as a repository for the Bondholders.

 

2.15         Other Liens.  The City and WDDF will keep the Project free from judgments and liens (except Permitted Encumbrances) and free from all claims, demands and encumbrances of whatsoever prior nature or character to the end that the security for the Bonds provided herein and in the Indenture will at all times be maintained and preserved free from any claim or liability which might hamper WDDF in conducting its business or interfere with WDDF’s use and occupancy of the Project, and the Trustee at its option (after first giving the City ten days’ written notice to comply therewith and failure of the City to so comply within such period) may defend against any and all actions or proceedings in which the validity hereof, or of the Indenture, is or might be questioned, or may pay or compromise any claim or demand asserted in any such action or proceeding; provided, however, that in defending such actions or proceedings or in paying or compromising such claims or demands the Trustee shall not in any event be deemed to have waived or released the City or WDDF from liability for or on account of any of its agreements and covenants contained herein or in the Indenture, or from its liability hereunder or_under the Indenture to defend the validity of the Indenture and the pledge of the Revenues made under the Indenture and to perform such agreements and covenants.

 

  

Page 9 of 23

  

 

2.16         Contiauing Disclosure.  The City has undertaken all responsibility for compliance with continuing disclosure requirements, and WDDF shall have no liability to the Owners or any other person with respect to S.E.C. Rule 15c2-12. Provided, however, to the extent that WDDF is an “Obligated Person” and the City is required under S.E.C. Rule 15c2-12 to provide continuing disclosure with respect to WDDF, WDDF agrees to provide the City with the necessary information in order to comply with its obligations under S.E.C. Rule 15c2-12. Notwithstanding any other provision of the Indenture, failure of the City, WDDF or the Trustee to comply with the Continuing Disclosure Certificate shall not be considered an Event of Default under the Indenture; however, the Trustee, upon payment of its fees and expenses, including counsel fees and expenses, and receipt of indemnity satisfactory to it, at the request of any Participating Underwriter (as defined in the Continuing Disclosure Certificate) or the Owners of at least 25% aggregate principal amount of Outstanding Bonds, shall, or any Owner or Beneficial Owner may, take such actions as may be necessary and appropriate, including seeking mandate or specific performance by court order, to cause the City and/or WDDF to comply with its obligations, or to cause the Trustee to comply with its obligations under Section 6.11 of the Indenture.

 

2.17         Covenant Not To Impair Tax Status Of Bonds.  Neither the City nor WDDF shall take nor permit nor suffer to be taken nor fail to take any action within their control which action or failure to act would impair the exclusion, if applicable, from gross income for federal income tax purposes of the Interest Portion of the Base Rent payments, including the calculation and payment of any rebate necessary as described in Section 6.05 of the Indenture to preserve the exclusion, if applicable, from gross income for federal income tax purposes of the Interest Portion of the Base Rent payments. Neither the City nor WDDF shall permit or direct the investment of any proceeds of the Tax-Exempt Bonds or the Lease Payments in such a manner that would result in the Tax-Exempt Bonds or the Lease being characterized as “arbitrage bonds” under Section 148 of the Code. The City and WDDF will comply with the provisions of the arbitrage certificate and the exhibits thereto executed by the City which relates to the issuance of the series of Tax-Exempt Bonds. The Indenture shall not be construed to constrain in any manner the ability of the Trustee to sell or dispose of the Project upon the occurrence of an Event of Default under Section 8.01(a) of the Indenture.

 

2.18         Fees, Charges and Expenses of Trustee. Registrar and Paying Agent.  The Trustee, the Registrar and the Paying Agent shall be entitled to payment or reimbursement for reasonable fees for Ordinary Services rendered hereunder and under the Indenture_and for all advances, counsel fees and other Ordinary Expenses reasonably and necessarily paid or incurred by them in connection with the provision of Ordinary Services from moneys available for such purpose in the Bond Fund for which fees WDDF and the City hereby agree to indemnify against and hold the Trustee harmless. For purposes hereof, fees for Ordinary Services provided for by their respective standard fee schedule shall be considered reasonable. In the event that it should become necessary for any of them to perform Extraordinary Services, they shall be entitled to reasonable extra compensation therefore and to reimbursement for reasonable and necessary Extraordinary Expenses incurred in connection therewith unless occasioned by their neglect or misconduct. The Trustee has been furnished a schedule attached to the Indenture as Exhibit “C” of the amounts required to be on deposit in the Bond Fund on each Interest Payment Date in order to meet future Debt Service Payments on the Series 2010 Bonds. Following an event of default, the Trustee shall have a first charge against the trust estate described here in the Indenture for its fees and expenses.

 

  

Page 10 of 23

  

 

ARTICLE 3

 

CONSTRUCTION OF THE PERMANENT  FACILITIES

3.1     Acquisition of Site.  The City shall acquire the WDDF Campus from Horizons Acquisitions 5, LLC pursuant to the terms of the Purchase and Sale Agreement. At least five (5) days prior to the Commencement Date of this Lease, the City shall deliver to WDDF copies of all documents obtained by the City in connection with its acquisition of the Site, including, without limitation, title information, surveys, environmental assessment reports, soil and ground water samples and all other information concerning the condition of the site.

 

3.2     Authorized Uses for WDDF Campus.  WDDF shall be authorized to utilize WDDF Campus for the purposes set forth in Section 4.1 ; and in addition, WDDF shall be authorized to lease or sublease portions of the Permanent Facilities to for-profit and not-for-profit entities for the uses authorized herein and in accordance with the terms of the Lease (collectively, the “Authorized Uses”).

 

3.3     Planning and Design of WDDF Campus and Permanent Facilities.  City shall consult with WDDF in the planning and design of the WDDF Campus and the Permanent Facilities. The parties shall mutually agree upon the architect selected to design the Permanent Facilities and the architectural criteria for the WDDF. The parties further agree that, if the cost estimates for construction of the Permanent Facilities exceed the Maximum Cost, WDDF and City shall have the right to conduct value engineering to reduce such cost estimates to the Maximum Cost; provided, however, that any such value engineering shall not modify the design of the Permanent Facilities in a manner that would reasonably be expected to jeopardize WDDF’s ability to operate as a technology and entertainment focused animated film, video game, visual effects, post production and/or related functions development studio and satisfy its obligations under the State Funding Agreement and hereunder. The parties acknowledge and agree that WDDF shall have no obligation to fund any construction costs for the Permanent Facilities. The parties acknowledge and agree that the City shall have no obligation to fund any construction costs beyond the $21,800,000.00 budget for Permanent Facilities

 

3.4     Infrastructure to Serve WDDF Campus.  WDDF acknowledges and agrees that the Infrastructure required to serve the WDDF Campus will be designed and constructed by the City. All infrastructure cost required for the WDDF Campus shall be part of the maximum construction cost.

 

  

Page 11 of 23

  

 

3.5     Construction of the WDDF Permanent Facilities.  (a) The Permanent Facilities shall consist of approximately 150,000 square feet of Gross Floor Area, subject however, to a reduction of the square footage upon mutual agreement of the City and WDDF. City shall use its best efforts to commence construction of the Permanent Facilities no later than April 1, 2010 and shall use its best efforts to complete construction of the Permanent Facilities no later than November 1, 2011. “Commencement of Construction” shall mean the commencement of site preparation (i.e. moving of dirt) for construction. “Completion of Construction” shall mean final completion of the Permanent Facilities in order that WDDF can occupy the WDDF Campus, and operate in accordance with the Authorized Uses, including, without limitation, the issuance of a certificate of occupancy by the City.

 

(b)     WDDF shall have the right to participate in all aspects of the design and construction of the Permanent Facilities. WDDF shall designate an individual to serve as its representative (the “WDDF Representative”), and the WDDF Representative and any other individuals designated by WDDF shall have complete access to the design documents, the construction documents and the construction site during all stages of construction. The City shall give WDDF advance notice of, and an opportunity to attend, all public hearings and all other meetings related to the design and/or construction. All proposed change orders to the plans and specifications shall be subject to the approval of WDDF and the City. WDDF shall approve or deny any requested Change Order within three days of receipt. If the changes are not approved or denied within 3 days, they shall be deemed approved. The City shall require the contractor to provide payment and performance bonds to the Permanent Facilities in accordance with the terms of the construction contract. Upon final completion of the Permanent Facilities, WDDF shall be provided with a set of as- built drawings for the Permanent Facilities, and the City shall assign to WDDF all construction warranties and all other contract rights under the construction contract.

 

3.6Force Majeure.  Either party may be excused for the period of any delay in the performance of any obligations contained herein when such delay is occasioned or caused by causes beyond the control of the party whose performance is so delayed and the time for performance shall be automatically extended for a like period. Such causes shall include without limitation, all labor disputes, judicial proceedings, civil disturbances, war, invasions, rebellions, sabotage, fires, floods, strikes, hurricanes or other acts of God.

 

ARTICLE 4

USE AND OCCUPANCY OF THE LEASED PROPERTY

 

4.1     Authorized Use of the Leased Property.  WDDF shall be authorized to utilize the Leased Property to (a) establish, operate and maintain an animated film, video game, visual effect or other post-production studio, including, (i) conducting training and outreach programs and (ii) performing ancillary services and related entertainment uses. WDDF shall not lease or sublease any portions of the leased property without the prior written consent of the City. Said consent shall not be unreasonably withheld or delayed, provided, however, that any lease or sublease of the Leased Property by WDDF shall not impair the tax-exempt status of any of the tax exempt Bonds issued to finance the construction of the Project.

 

4.2Waste or Nuisance.  WDDF shall not commit or suffer to be committed any waste upon the Leased Property or otherwise materially impair the value of City’s interest in the Leased Property.

 

  

Page 12 of 23

  

 

4.3Compliance with Applicable Laws.  WDDF shall maintain and use the Leased Property in accordance with all applicable federal, state and local laws, ordinances, governmental rules and regulations whether now existing or hereafter enacted or promulgated.

 

4.4Utilities.  During the term of this Lease, WDDF shall procure all utilities and services necessary for the operation of the Leased Property and shall promptly pay all costs and expenses related to all utilities and services supplied to or used on the Leased Property, including, water, sewer, gas, electricity, telephone, trash collection, and irrigation services.

 

4.5Insurance.  The WDDF shall indemnify and hold harmless the City, and its Officers and their employees, from liabilities, damages, losses, and costs, including but not limited to, reasonable attorney’s fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the design professional/WDDF of WDDF and all persons employed or utilized by the WDDF in the performance of this Lease.

 

WDDF shall, on a primary hasis and at its sole expense, agree to maintain in full force and effect at all times during the life of this Lease, insurance coverage, limits, including endorsements, as described herein. The requirements contained herein, as well as City’s review or acceptance of insurance maintained by WDDF are not intended to and shall not in any manner limit or qualify the liabilities and obligations assumed by WDDF under this Contract.

 

The City of Port St. Lucie shall provide property insurance, including business income to cover the Lease Payments, business interruption, and equipment breakdown insurance for the building and equipment the City may own and lease to WDDF. If the property lies within a special flood hazard area, a flood policy will also be obtained through the National Flood insurance Program. WDDF shall be responsible for purchasing insurance for business personal property that is not owned or leased to WDDF by the City of Port St. Lucie.

 

WDDF shall agree to maintain Workers’ Compensation Insurance & Employers’ Liability in accordance with Chapter 440, Florida Statutes.

 

WDDF shall agree to maintain Business Automobile Liability at a limit of liability not less than $500,000 each occurrence for any auto including owned, non-owned and hired automobiles. In the event WDDF does not own any automobiles the Business Auto Liability requirement shall be amended allowing WDDF to agree to maintain only Hired & Non-Owned Auto Liability. This amended requirement may be satisfied by way of endorsement to the Commercial General Liability, or separate Business Auto Coverage form.

 

Commercial General Liability Insurance during the lifetime of this Contract shall have minimum limits of $1,000,000 per occurrence, $2,000,000 aggregate for Personal Injury, Bodily Injury, and Property Damage Liability and shall apply on a per location basis. Coverage shall respond as Primary. Coverage shall include Premises and/or Operations, Independent Contractors, Products and/or Complete Operations, Contractual Liability to cover the Indemnification agreement as set forth herein and Broad Form Property Damage Liability. Coverage is to include a Cross Liability or Severability of Interests provision as provided under the standard ISO form. Separation of Insureds Clause. All insurance policies shall be issued from a company or companies duly licensed by the State of Florida. All policies shall be on an occurrence-made basis; the City shall not accept claims-made policies.

 

  

Page 13 of 23

  

 

Except as to Workers’ Compensation and Employers’ Liability, said Certificate(s) and policies shall clearly state that coverage required by the Contract has been endorsed to include the City of Port St. Lucie, a political subdivision of the State of Florida, its officers, agents and employees as Additional Insured with a CG 20 11- Managers or Lessors of Premises endorsement, or similar endorsement, to its Commercial General Liability. The name for the Additional Insured endorsement issued by the insurer shall read “City of Port St. Lucie, political subdivision of the State of Florida, its officers, employees and agents, and be location specific. The Certificate of Insurance and policy shall unequivocally provide thirty (30) days written notice to the City prior to any adverse changes, cancellation, or non-renewal of coverage thereunder. Said liability insurance must be acceptable by and approved by the City as to form and types of coverage.

 

WDDF shall agree by entering into this Lease to a Waiver of Subrogation for each required policy. When required by the insurer, or should a policy condition not permit an Insured to enter into a pre-loss Contract to waive subrogation without an endorsement WDDF shall agree to notify the insurer and request the policy be endorsed with a Waiver of Transfer of Rights of Recovery Against Others, or its equivalent.

 

In the event the premises are sublet, it shall be the responsibility of WDDF to ensure that all tenants comply with the same insurance requirements referenced above. Also, in the event WDDF hires any contractors to perform any form of work on premises, said contractors and any subcontractors shall furnish a Certificate of Insurance naming the City as Additional Insured as referenced above.

 

All deductible amounts shall be paid for and be the responsibility of WDDF for any and all claims under this Lease.

 

WDDF may satisfy the minimum limits required above for Commercial General Liability, Business Auto Liability, and Employer’s Liability coverage under Umbrella or Excess Liability. The Umbrella or Excess Liability shall have an Aggregate limit not less than the highest “Each Occurrence” limit for Commercial General Liability, Business Auto Liability, or Employer’s Liability. When required by the insurer, or when Umbrella or Excess Liability is written on “Non-Foliow Form,” the City shall be endorsed as an “Additional Insured.”

 

The City, by and through its Risk Management Department, reserves the right, but not the obligation, to review and reject any insurer providing coverage.

 

4.6Destruction of Permanent Facilities.  The City shall maintain property and casualty insurance for the Permanent Facilities and Leased Property. The City shall be entitled to any insurance proceeds in the event of a covered loss. The City shall use said funds to the extent allowed to retire any outstanding City issued debt instruments and/or bonds contemplated by this Lease pursuant to Section 4.01 (a) of the Indenture. Upon full payment and satisfaction of the debt instruments and/or bonds this Lease shall terminate. If there are any remaining proceedings, said proceeds shall go to City.

 

  

Page 14 of 23

  

 

4.7     Maintenance and Repair.  (a) City shall have no obligation under this Lease to make or conduct any maintenance or repairs to the Leased Property. WDDF shall, at its sole cost and expense, maintain the Leased Property and any improvements and appurtenances thereto, in good and safe condition and repair consistent with good business practice and industry standard.

 

  (b)City shall have the right, upon reasonable prior written notice to WDDF, to annually enter the Leased Property during normal business hours for the purpose of inspection of the Leased Property for compliance with the provisions of this Lease, subject to reasonable restrictions imposed by WDDF for safety and security purposes due to the nature of WDDF’ operations. City’s exercise of its inspection right shall not unreasonably interfere with or disrupt WDDF’ operations within the Leased Property.

 

  (c)WDDF shall, at its sole cost and expense, keep the Leased Property clean at all times. All refuse is to be removed from the Leased Property at WDDF’ sole cost and expense and WDDF will keep such refuse in proper containers until removed.

 

4.8.    Condemnation. In the event of any taking by any other governmental or quasi governmental authority (including, without limitation, any community development district), of all or any material portion of the leased property, WWDF shall have the right to terminate this Lease by giving written notice thereof to the City, in which event WWDF shall be relieved of all further obligation hereunder. For the purpose of this section, the term “material portion of the lease property” shall mean the taking of any portion of the leased property, which, in the reasonable judgment of WDDF, would have a material impact upon its use and operation of the leased property. The City shall have the right to receive any condemnation award to the extent permitted by Florida law and the City shall use such proceeds to retire the debt instruments and/or bonds contemplated by this Lease pursuant to Section 4.01 (a) of the Indenture. Notwithstanding the foregoing, WDDF shall have the right to receive any business damages awards in excess of the amount necessary to retire in full the outstanding City issued debt instruments and/or bonds contemplated by this Lease.

 

ARTICLE 5

OWNERSHIP OF THE LEASED PROPERTY

5.1     Title to Leased Property.

 

  (a)        City holds and shall maintain fee simple title to the Leased Property. City acknowledges that WDDF shall own any improvements constructed on the Leased Property by WDDF.

 

  (b)       WDDF shall have the right to terminate this Lease at any time upon 120 days prior written notice by paying to the City the amount necessary to pre-pay 100% of the debt instruments/bonds issued to fmance the Permanent Facilities, and any other outstanding payments/fees due to the City, plus One Dollar ($1.00). At that time the City shall execute and deliver a special warranty deed conveying fee simple ownership of the Leased Property to WDDF, subject only to those title matters referenced in Exhibit “C” attached hereto and made a part of hereof, and such other matters which may be acceptable to WDDF in its sole discretion, (the “Permitted Exceptions”). In the event that at the time of conveyance of the Leased property to WDDF, there are any title matters affecting the Lease Property other than Permitted Exceptions, the City and WDDF shall cooperate in good faith to cure such title matters.

 

  

Page 15 of 23

  

 

  (c)         Depreciation.  WDDF shall be entitled to depreciation on the buildings, other structures and improvements and fixtures comprising the Permanent Facilities which are now or shall subsequently be erected upon the Site, provided WDDF is not in default of any of the terms and conditions of this Lease Agreement.

 

  (d)        Acquisition of WDDF Campus.  Upon WDDF making full payment of the outstanding debt instruments and/or bonds issued by the City for the leased property and any other outstanding payment, fees, expenses due with respect to such instruments/bonds, WDDF shall be entitled to acquire title to the leased property. The City shall execute a Special Warranty Deed and any other related documents required to transfer title to the leased property to WDDF.

 

ARTICLE 6

DEFAULTS AND REMEDIES

6.1     City Events of Default.  The occurrence of the following event shall constitute a “City Default” hereunder:

 

  (a)         a material failure to observe or perform any of the terms, covenants, conditions, obligations or provisions of this Lease to be observed or performed by City where such failure continues for a period of thirty (30) days after written notice thereof from WDDF to City; provided, however, that if the nature of such failure is such that more than thirty (30) days are reasonably required for City to complete its cure, then City shall not be deemed to be in Default if City has commenced such cure within the thirty (30) day period and thereafter diligently pursues such cure to completion.

 

  (b)         the material breach of any condition, term, provision, covenant, representation or warranty by the City contained in the City Grant Agreement. If such material breach is not cured after written notice from WDDF to the City, and a reasonable opportunity (which shall not be less than thirty (30)) to cure such material breach, the City shall be in default.

 

6.2     WDDF Events of Default.  The occurrence of any one or more of the following events shall constitute a “WDDF Default” hereunder:

 

  (a)         vacating, abandoning or closing WDDF Florida’s operations in Port St. Lucie or, after occupancy of the Permanent Facilities, relocating WDDF Florida’s primary operations outside of Port St. Lucie for a period longer than thirty (30) days;

 

  (b)         failure to continuously operate the Permanent Facilities as is consistent with the Authorized Uses, on and after occupancy of the Permanent Facilities;

 

  (c)         failure to pay when due;

 

(i)        the Basic Rent pursuant to Section 2.3 hereof;

 

  

Page 16 of 23

  

 

(ii)       the security payment pursuant to Section 2.4 hereof; and

 

(iii)      any additional rent pursuant to Section 2.5 hereof.

 

  (d)       a  material   failure  to  observe  or  perform   any  of  the  terms,  covenants, conditions, obligations or provisions of this Lease or the Indenture to be observed or performed by WDDF, where such failure continues for a period of thirty (30) days after written notice thereof from City to WDDF; provided, however, that if the nature of such failure is such that more than thirty (30) days are reasonably required for WDDF to complete its cure, then WDDF shall not be deemed to be in Default if WDDF has commenced such cure within the thirty (30) day period and thereafter diligently pursues such cure to completion;

 

  (e)        the material breach of any condition, term, provision, representation or warranty by WDDF contained in the City Grant Agreement. If such material breach is not cured after written notice from City to WDDF, and a reasonable opportunity, which shall not be less than thirty (30) days) to cure such material breach, WDDF shall be in default;

 

  (f)        the declaration by the Governor’s Office of Tourism, Trade and Economic Development in the State of Florida (“OTTED”) of a material default by WDDF in the State Funding Agreement that results in (i) a withdrawal of funding, or (ii) the imposition of material sanctions and/or required reimbursements by OTTED;

 

  (g)        the making by WDDF of any general assignment or general arrangement for the benefit of creditors; the filing by or against WDDF of a petition to have WDDF adjudged bankrupt or a petition for reorganization under any law relating to bankruptcy (unless, in the case of any petition filed against WDDF, such petition is dismissed within sixty (60) days after WDDF receives notice of such petition); or the appointment of a trustee or receiver to take possession of all or substantially all of WDDF’s assets, where such possession is not restored to WDDF within thirty (30) days of such appointment.

 

6.3     Remedies for Default. Following the occurrence and continuance of a Default during the Term of this Lease, the non-defaulting party may, upon prior written notice to the defaulting party,

  (a)         terminate this Lease and the City Grant Agreement, and

 

  (b)        additionally,  the  non-defaulting  party  shall  have  the  right  to  have  the provisions of this Lease enforced by any court having equity jurisdiction, it being acknowledged that any such Default will cause irreparable injury to the non-defaulting party and that money damages will not provide an adequate remedy.

 

  (c)         the rights and remedies under this Section shall not limit the City’s ability to seek other rights provided by the this Lease and/or the City Grant Agreement, or by law or in equity, including the right of specific performance and the ability to seek relief from any automatic stay under the United States Bankruptcy Code.

 

  

Page 17 of 23

  

 

6.4     Limitations on Liability. It is specifically understood and agreed that there shall be absolutely no corporate or personal liability or recourse for the amounts funded hereunder, or the performance of any obligations hereunder against any employee, shareholder, partner, director, trustee, or officer (whether past, present or future) of WDDF, any parent, subsidiary or affiliate thereof, and City shall look solely to the interest of WDDF in the Site and the Permanent Facilities for the satisfaction of each and every remedy to City in the event of any WDDF Default. Notwithstanding the foregoing, in the event of fraud or material misrepresentation, the provisions of this paragraph are void.

 

6.5     Waiver of Monetary Damages. Notwithstanding any provision in this Lease to the contrary, in no event shall any party or its respective officers, directors, members, partners, employees or representatives, be liable hereunder at any time for compensatory, punitive, consequential, special, or indirect loss or damage of the other party, including loss of profit, loss of revenue or any other special or incidental damages, whether in contract, tort (including negligence), strict liability or otherwise, and each party hereby expressly releases the other party and its officers, directors, members, partners, employees and representatives therefrom. Notwithstanding the foregoing, in the event of fraud or material misrepresentation, the provisions of this paragraph are void.

ARTICLE 7

INDEMNIFICATION

 

7.1    General  Indemnification.  Subject  to  Section  6.4, WDDF  shall indemnify and hold City, the Trustee, their agents, employees, officers and Council individually, a “Covered Person,” and collectively, “Covered Persons” harmless from and against any and all claims, liabilities, expenses, losses, costs, damages, fines, penalties and causes of action of every kind and character including the costs of defenses for any such claims collectively, “Damages”, incurred or suffered by a Covered Person which is due to any act or omission of WDDF or its agents, employees, contractors, invitees, licensees or subtenants to or of the Permanent Facilities collectively, “WDDF Parties” arising out of the use, operation or occupancy by the WDDF Parties of the Leased Property or any other improvements, now existing or hereinafter constructed or placed on or within the Leased Property.

 

7.2     Survival of Indemnification Obligations. The obligations arising under this Article VIII shall survive the expiration or termination of this Lease.

 

ARTICLE 8

MISCELLANEOUS  PROVISIONS

 

8.1     No Assignment; Binding Effect.     (a) Neither this Agreement nor any right, interest or obligation hereunder may be assigned by any party except by the City, pursuant to the Assignment Agreement, without the prior written consent of the other Party and any attempt to do so will be void, except for assignment by WDDF to a wholly-owned subsidiary or parent company incorporated and organized by WDDF to hold the assets or equity of WDDF Florida, and (b) WDDF may assign this Agreement to any successor-in-interest to all or substantially all of the assets of WDDF; provided, however, that any such successor-in-interest must assume in writing all of the rights and obligations of WDDF under this Agreement. Any merger, consolidation or reorganization of WDDF that results in a change of control shall be deemed an assignment for purposes of this Section. This Agreement is binding upon, inures to the benefit of and is enforceable by the parties and their respective successors and permitted assigns.

 

  

Page 18 of 23

  

 

8.2     No Third Party Beneficiary. Except with respect to the Trustee for the benefit of the holders of the Series 2010 Bonds, the terms and provisions of this Lease are intended solely for the benefit of each party and their respective successors or permitted assigns, and it is not the intent of the parties to confer third-party beneficiary rights upon any other Person other than any Person entitled to indemnification pursuant to Article VII.

 

8.3     Waiver. Any term or condition of this Lease may be waived at any time by the party that is entitled to the benefit thereof, but no such waiver shall be effective unless set forth in a written instrument duly executed by or on behalf of the party waiving such term or condition. No waiver by any party of any term or condition of this Lease, in any one or more instances, shall be deemed to be construed as a waiver of the same or any other term or condition of this Lease on any future occasion.

 

8.4     Notices. All notices, requests and other communications hereunder must be in writing and will be deemed to have been duly given if delivered by: (i) hand delivery; (ii) certified mail, return receipt requested postage prepaid; (iii) nationally recognized overnight commercial courier, charges prepaid; or (iv) facsimile with confirmation of transmission to each of the parties as follows:

	
If to City

	
City of Port St.  Lucie 

121 SW Port St. Lucie Boulevard

Port St. Lucie, Florida  34984

Attention: City Manager

Facsimile Number: (772) 871-5248

	
with a copy to:

	
City of Port St.  Lucie

121 SW Port St. Lucie Boulevard

Port St. Lucie, Florida  34984

Attention: City Attorney

Facsimile Number: (772) 871-5255

 

	
If to WDDF:

	
Wyndcrest DD Florida, Inc.

11450 SE Dixie Highway, Suite 104

Hobe Sound, Florida 33455

Attention: Chief Operating  Officer

Facsimile Number: (772) 545-9065

 

	
with copies to:

	
Gunster, Yoakley & Stewart, P.A.

777 S. Flagler Drive, Suite 500 East

West Palm Beach, FL 33401

Attention: Lewis F. Crippen, Esq.

Facsimile Number: (561) 671-2451

	
If to Trustee:

	

TD Bank, National Association, as Trustee

7545 Centurion Parkway, #402

Jacksonville, FL 32256

Attention: Jane Pope

Facsimile Number: 904-645-8447

  

Page 19 of 23

  

 

8.5     Amendment. This Lease may be amended, supplemented or modified only by a written instrament duly executed by or on behalf of eaeh party.

 

  (a)         Amendments Not Requiring Consent of Registered Owners and Trustee. Without the consent of or notice to the Registered Owners, a Credit Facility Issuer, or the Trustee, WDDF and the City may enter into any amendment, change or modification of this Lease as may be required (i) by the provisions of this Lease or the Indenture, (ii) in connection with the issuance of Additional Bonds, as specified in the Indenture, (iii) for the purpose of curing any ambiguity, inconsistency or formal defect or omission in this Lease, (iv) in connection with an amendment or to effect any purpose for which there could be an amendment of the Indenture pursuant to Section 9.02 thereof, (v) pursuant to this Section 8.5(a) of this Lease, provided that the Lease Payments will not be modified except as permitted by Section 12.01 of the Indenture, or (vi) in connection with any other change therein which is not to the prejudice of the Trustee or the Registered Owners of the Bonds.

 

  (b)        Amendments Requiring Consent of Registered Owners and Credit Facility Issuer. Except for the amendments, changes or modifications contemplated in subsection (a) of this Section and Section 12.01 of the Indenture WDDF and the City shall not enter into:

 

(i)      any amendment, change or modification of this Lease which would change the amount or time as of which Lease Payments are required to be paid (except amendments, changes or modifications which result in a decrease in Lease Payments required to be paid as a result of refunding Outstanding Bonds), without the giving of notice as provided in this Section of the proposed amendment, change or modification and receipt of the written consent thereto of the Credit Facility Issuer and the Registered Owners of all of the then Outstanding Bonds, or

 

(ii)     any other amendment, change or modification of this Lease without the giving of notice as provided in this Section of the proposed amendment, change or modification and receipt of the written consent thereto of the Credit Facility Issuer and the Registered Owners of Bonds representing not less than a majority of the aggregate Principal Portion of the Bonds then Outstanding.

 

The consent of the Registered Owners and Credit Facility Issuers shall be obtained as provided in Sections 9.03 and 9.07, respectively, of the Indenture.

 

If the City and WDDF shall enter into any amendment provided in Secfion 12.01 and Section 12.02 of the Indenture and Section 8.5(a) of (b) hereof, the Trustee shall cause notice of the proposed amendment, change or modification to be provided in the manner which is required by Sections 9.03 and 9.07 of the Indenture with respect to notice of Supplemental Indenture. The notice shall set forth briefiy the nature of the proposed amendment, change or modification and shall state that copies of the instrument or document embodying it are on file at the designated corporate trust office of the Trustee for inspecfion by all Registered Owners.

 

  

Page 20 of 23

  

 

8.6     Invalid Provisions. If amy provision of this Agreement is held to be illegal, invalid or unenforceable under any present or future law, (a) such provision will be fully severable, (b) this Agreement will be construed and enforced as if such illegal, invalid or unenforceable provision had never comprised a part hereof, and (c) the remaining provisions of this Agreement will remain in full force and effect and will not be affected by the illegal, invalid or unenforceable provision or by its severance herefrom.

 

8.7     Governing Law. This Agreement shall be governed by the laws of the State of Florida, without regard to principles of conflicts of laws.

 

8.8     Consent to Jurisdiction. Each of the parties hereby irrevocably consents and agrees that any legal action or proceedings with respect to this Agreement may be brought in any of the courts of the State of Florida located in St. Lucie County, Florida or the courts of the United States of America for the Southern District of Florida having subject matter jurisdiction and, by execution an delivery of this Agreement and such other documents executed in connection herewith, each party hereby (i) accepts the non-exclusive jurisdiction of the aforesaid courts, (ii) irrevocably agrees to be bound by any final judgment (after any all appeals) of any such court with respect to such documents, (iii) irrevocably waives to the fullest extent permitted by law, any objection that it may now or hereafter have to the laying of venue of any suit, action or proceedings with respect to such documents brought in any such court, and further irrevocably waives to the fullest extent permitted by law, any claim that any such suit, action or proceedings brought in any such court has been brought in an inconvenient forum, (iv) agrees that service of process in any such action may be effected by mailing a copy thereof by registered or certified mail or any substantially similar form of mail, postage prepaid, to such party at the address set forth in Section 8.4, or at such other address of which the other party has been notified, and (v) agrees that nothing herein shall affect the right to effect service of process in any other manner permitted by law or limit the right to bring suit, action or proceeding in any other jurisdiction.

 

8.9     Waiver of Jury Trial. EACH OF THE PARTIES HERETO HEREBY KNOWINGLY, VOLUNTARILY AND INTENTIONALLY WAIVE THE RIGHT ANY OF THEM MAY HAVE TO A TRIAL BY JURY IN RESPECT OF ANY LITIGATION BASED HEREON, OR ARISING OUT OF, UNDER OR IN CONNECTION WITH THIS AGREEMENT AND ANY AGREEMENT CONTEMPLATED TO BE EXECUTED IN CONJUNCTION HEREWITH, OR ANY COURSE OF DEALING, STATEMENTS (WHETHER VERBAL OR WRITTEN) OR ACTIONS OF ANY PARTY HERETO. THIS PROVISION IS A MATERIAL INDUCEMENT FOR THE PARTIES ENTERING INTO THIS AGREEMENT.

 

8.10   Relationship of the Parties / No Joint Venture. The parties hereby agree that it is their intention to create only the relationship of landlord and tenant, and neither this Lease, nor any term, provision, payment or right hereunder shall in any way or for any purpose, constitute or cause the City to become or be deemed a partner of WDDF in the conduct of its business, or otherwise, or to cause City to become or be deemed a joint adventurer or a member of a joint enterprise with WDDF, nor shall this Lease, or any term or payment required herein, confer or be deemed to confer any interest upon City in the conduct of WDDF’s business.

 

8.11   Headings. The headings used in this Lease have been inserted for convenience of reference only and do not define or limit the provisions hereof.

 

8.12   Time is of the Essence. With regard to all dates and time periods set forth or referred to in this Lease, time is of the essence.

 

  

Page 21 of 23

  

 

8.13   Counterparts. This lease may be executed in any number of counterparts, each of which will be deemed an original, but all of which together will constitute one and the same instrument.

 

8.14   Recording of Lease. Upon the execution of this Lease, it shall be recorded in the public records of St. Lucie County, Florida.

 

IN WITNESS WHEREOF, City has caused this Lease to be executed and delivered by [the Chair of the Council] and the seal of the City to be affixed hereto and attested to by the Clerk of the Council and WDDF has caused this Lease to be executed and delivered by its duly authorized representative as of the date first above written.

 

	
ATTEST:

	 	
CITY OF PORT ST. LUCIE,

	 	 	
a Florida municipal corporation

	  	 	  
	
By:

	
/s/ Karen A. Phillips

	 	
By:

	
/s/ Patricia P. Christensen

	
Name:

	
Karen A. Phillips

	 	
Name:

	
Patricia P. Christensen

	
Title:

	
City Clerk

	 	
Title:

	
Mayor

	  	 	  
	  	 	
APPROVED AS TO FORM AND SUFFICIENCY:

	  	 	  
	  	 	
By:

	
/s/ Pam E. Booker Hakim

	  	 	
Name:

	
Pam E. Booker Hakim

	  	 	
Title:

	
Senior Assistant City Attorney

	  	 	  
	  	 	
WYNDCREST DD FLORIDA, INC., a corporation

organized under the laws of the State of Florida

	  	 	  
	  	 	
By:

	
/s/ Jonathan Teaford

	  	 	
Name:

	
Jonathan Teaford

	  	 	
Title:

	
President

 

  

Page 22 of 23

  

 

EXHIBIT “A”

 

LEGAL DESCRIPTION

 

LEGAL DESCRIPTION

 

BEING A PARCEL OF LAND LYING IN A PORTION OF LOT 1, ACCORDING TO THE PLAT OF TRADITION PLAT NO. 59, AS RECORDED IN PLAT BOOK 60, PAGE 8, PUBLIC RECORDS OF ST. LUCIE COUNTY, FLORIDA, BEING MORE PARTICULARLY DESCRIBED AS FOLLOWS;

COMMENCE AT THE SOUTHEAST CORNER OF SAID LOT 1; THENCE ALONG THE EASTERLY LINE OF SAID LOT 1 THE FOLLOWING 4 COURSES AND DISTANCES; THENCE N08’20’33”W A DISTANCE OF 22:76 FEET; THENCE N05’33’00”W A DISTANCE OF 296.59 FEET; THENCE N06’47”54”W A DISTANCE OF 44.39 FEET TO THE POINT OF BEGINNING OF THE FOLLOWING DESCRIBED PARCEL;

THENCE S85*21’57”W A DISTANCE OF 778.41 FEET; THENCE N04*38’03”W A DISTANCE OF 340.46 FEET TO THE BEGINNING OF A CURVE CONCAVE TO THE WEST HAVING A RADIUS OF 1,092.61 FEET; THENCE NORTHERLY ALONG THE ARC OF SAID GURVE A DISTANCE OF 170.41 FEET THROUGH A CENTRAL ANGLE OF 08*56’10”; THENCE S82*05’00”W A DISTANCE OF 349.90 FEET TO THE EASTERLY LINE OF TRACT R — 39 ACCORDING TO THE PLAT OF TRADITION PLAT NO. 36, AS RECORDED IN PLAT BOOK 49, PAGE 28, AND TO AN INTERSECTION WITH A NON TANGENT CURVE CONCAVE TO THE WEST, HAVING A RADIUS OF 745.21 FEET, THE GHORD OF WHICH BEARS N18*34’10”W; THENCE NORTHERLY ALONG THE ARC OF SAID CURVE, AND ALONG SAID EASTERLY LINE OF TRACT R — 3 9 , A DISTANCE OF 61.07 FEET THROUGH A CENTRAL ANGLE OF 04*41’43” TO THE SOUTH LINE OF PARCEL 3 OF SAID TRADITION PLAT NO. 36; THENCE N82*05’00”E, ALONG SAID SOUTH LINE, A DISTANCE OF 289.39 FEET TO THE EASTERLY LINE OF SAID PARCEL 3; THENCE N07*55’00”W, ALONG SAID EASTERLY LINE, A DISTANCE OF 250.00 FEET TO THE NORTHERLY LINE OF SAID LOT 1; THENCE ALONG THE NORTHERLY AND EASTERLY LINE OF SAID LOT 1 THE FOLLOWING 9 COURSES AND DISTANCES; THENCE N79*05”50”E A DISTANCE OF 176.09 FEET; THENCE N81*30’32”E A DISTANCE OF 158.84 FEET; THENCE N7911’01”E A DISTANCE OF 39.04 FEET; THENCE N85”27”23”E A DISTANCE OF 147.21 FEET TO THE BEGINNING OF A CURVE CONCAVE TO THE SOUTHWEST HAVING A RADIUS OF 350.00 FEET; THENCE SOUTHEASTERLY ALONG THE ARC OF SAID CURVE A DISTANCE OF 387.97 FEET THROUGH A CENTRAL ANGLE OF 63*30’39” TO THE POINT OF COMPOUND CURVATURE WITH A CURVE CONCAVE TO THE WEST, HAVING A RADIUS OF 500.00 FEET; THENCE SOUTHERLY ALONG THE ARC OF SAID CURVE, A DISTANCE 259.03 FEET THROUGH A CENTRAL ANGLE OF 29*40’59”; THENCE S01*20’59”E A DISTANCE OF 147.45 FEET; THENCE S04*31’55”E A DISTANCE OF 100.31 FEET; THENCE S06*47’54”E A DISTANCE OF 156.70 FEET TO THE POINT OF BEGINNING.

 

CONTAINING 15.485 ACRES, MORE OR LESS.

 

NOTE: THIS IS NOT A SKETCH OF SURVEY, BUT ONLY A GRAPHIC DEPICTION OF THE DESCRIPTION SHOWN HEREON. THERE HAS BEEN NO FIELD WORK,VIEWING OF THE SUBJECT PROPERTY OR MONUMENTS SET IN CONNECTION WITH THE PREPARATION OF THE INFORMATION SHOWN HEREON.

NOTE: LANDS SHOWN HEREON WERE NOT ABSTRACTED FOR RIGHT - OF - WAY AND/OR EASEMENTS OF RECORD.

	
/s/ Michael T. Kolodziejczyk

	 	
7-27-09

	
Michael T. Kolodziejczyk

	 	
Signature Date

	
Professional Surveyor and Mapper

	 
	
Florida Certificate No. 3864

	REVISION: CHANGED AREA & LEGAL DESCRIPTION GLM 7–27–09
	  	
Sheet 1 of 2

 

	
DESCRIPTION

 

OF

	
File:

 

Date:

	
08–242–WA05 

S&d–15oc–A.dwg

7–08–2009

	

	
CULPEPPER & TERPENING, INC

CONSULTING ENGINEERS | LAND SURVEYORS

2980 SOUTH, 25th STREET

FORT PIERCE, FLORIDA 34981

PHONE 772-464-3537 FAX 772-464-9497

www.ct-eng.com

state of florida certification no. lb 4286

	
15 ACRE PARCEL

	 	 
	 	
Tech:

	
GLM

 

  

Page 23 of 23

  

 

EXHIBIT B

 

DEBT SERVICE PAYMENTS

 

	  	 	
Series 2010A

	 	 	
Series 201OB

	 	 	 	 	 	 	 
	
Date

	 	
Bonds

	 	 	
Bonds

	 	 	
Total

	 	 	
Annual Total

	 
	  	 	 	 	 	 	 	 	 	 	 	 	 
	
09/01/2010

	 	$	321,418.04	 	 	$	360,368.54	 	 	$	681,786.58	*	 	$	681,786.58	 
	
03/01/2011

	 	 	466,574.58	 	 	 	523,115.63	 	 	 	989,690.21	*	 	 	 	 
	
09/01/2011

	 	 	466,574.58	 	 	 	523,115.63	 	 	 	989,690.21	*	 	 	1,979,380.42	 
	
03/01/2012

	 	 	466,574.58	 	 	 	523,115.63	 	 	 	989,690.21	*	 	 	 	 
	
09/01/2012

	 	 	1,936,574.58	 	 	 	553,115.63	 	 	 	2,489,690.21	 	 	 	3,479,380.42	 
	
03/01/2013

	 	 	445,862.28	 	 	 	522,815.63	 	 	 	968,677.91	 	 	 	 	 
	
09/01/2013

	 	 	1,960,862.28	 	 	 	552,815.63	 	 	 	2,513,677.91	 	 	 	3,482,355.82	 
	
03/01/2014

	 	 	417,652.98	 	 	 	522,478.13	 	 	 	940,131.11	 	 	 	 	 
	
09/01/2014

	 	 	1,987,652.98	 	 	 	557,478.13	 	 	 	2,545,131.11	 	 	 	3,485,262.22	 
	
03/01/2015

	 	 	382,665.53	 	 	 	521,996.88	 	 	 	904,662.41	 	 	 	 	 
	
09/01/2015

	 	 	2,022,665.53	 	 	 	556,996.88	 	 	 	2,579,662.41	 	 	 	3,484,324.82	 
	
03/01/2016

	 	 	343,658.13	 	 	 	521,471.88	 	 	 	865,130.01	 	 	 	 	 
	
09/01/2016

	 	 	2,063,658.13	 	 	 	556,471.88	 	 	 	2,620,130.01	 	 	 	3,485,260.02	 
	
03/01/2017

	 	 	300,030.33	 	 	 	520,859.38	 	 	 	820,889.71	 	 	 	 	 
	
09/01/2017

	 	 	2,105,030.33	 	 	 	555,859.38	 	 	 	2,660,889.71	 	 	 	3,481,779.42	 
	
03/01/2018

	 	 	251,087.75	 	 	 	520,203.13	 	 	 	771,290.88	 	 	 	 	 
	
09/01/2018

	 	 	2,156,087.75	 	 	 	555,203.13	 	 	 	2,711,290.88	 	 	 	3,482,581.76	 
	
03/01/2019

	 	 	195,461.75	 	 	 	519,503.13	 	 	 	714,964.88	 	 	 	 	 
	
09/01/2019

	 	 	2,210,461.75	 	 	 	559,503.13	 	 	 	2,769,964.88	 	 	 	3,484,929.76	 
	
03/01/2020

	 	 	135,112.50	 	 	 	518,678.13	 	 	 	653,790.63	 	 	 	 	 
	
09/01/2020

	 	 	2,270,112.50	 	 	 	558,678.13	 	 	 	2,828,790.63	 	 	 	3,482,581.26	 
	
03/01/2021

	 	 	70,101.75	 	 	 	517,828.13	 	 	 	587,929.88	 	 	 	 	 
	
09/01/2021

	 	 	2,335,101.75	 	 	 	557,828.13	 	 	 	2,892,929.88	 	 	 	3,480,859.76	 
	
03/01/2022

	 	 	-	 	 	 	516,978.13	 	 	 	516,978.13	 	 	 	 	 
	
09/01/2022

	 	 	-	 	 	 	2,256,978.13	 	 	 	2,256,978.13	 	 	 	2,773,956.26	 
	
03/01/2023

	 	 	-	 	 	 	480,003.13	 	 	 	480,003.13	 	 	 	 	 
	
09/01/2023

	 	 	-	 	 	 	2,295,003.13	 	 	 	2,295,003.13	 	 	 	2,775,006.26	 
	
03/01/2024

	 	 	-	 	 	 	440,300.00	 	 	 	440,300.00	 	 	 	 	 
	
09/01/2024

	 	 	-	 	 	 	2,335,300.00	 	 	 	2,335,300.00	 	 	 	2,775,600.00	 
	
03/01/2025

	 	 	-	 	 	 	397,662.50	 	 	 	397,662.50	 	 	 	 	 
	
09/01/2025

	 	 	-	 	 	 	2,377,662.50	 	 	 	2,377,662.50	 	 	 	2,775,325.00	 
	
03/01/2026

	 	 	-	 	 	 	351,875.00	 	 	 	351,875.00	 	 	 	 	 
	
09/01/2026

	 	 	-	 	 	 	2,421,875.00	 	 	 	2,421,875.00	 	 	 	2,773,750.00	 
	
03/01/2027

	 	 	-	 	 	 	300,125.00	 	 	 	300,125.00	 	 	 	 	 
	
09/01/2027

	 	 	-	 	 	 	2,475,125.00	 	 	 	2,475,125.00	 	 	 	2,775,250.00	 
	
03/01/2028

	 	 	-	 	 	 	245,750.00	 	 	 	245,750.00	 	 	 	 	 
	
09/01/2028

	 	 	-	 	 	 	2,525,750.00	 	 	 	2,525,750.00	 	 	 	2,771,500.00	 
	
03/01/2029

	 	 	-	 	 	 	188,750.00	 	 	 	188,750.00	 	 	 	 	 
	
09/01/2029

	 	 	-	 	 	 	2,583,750.00	 	 	 	2,583,750.00	 	 	 	2,772,500.00	 
	
03/01/2030

	 	 	-	 	 	 	128,875.00	 	 	 	128,875.00	 	 	 	 	 
	
09/01/2030

	 	 	-	 	 	 	2,643,875.00	 	 	 	2,643,875.00	 	 	 	2,772,750.00	 
	
03/01/2031

	 	 	-	 	 	 	66,000.00	 	 	 	66,000.00	 	 	 	 	 
	
09/01/2031

	 	 	-	 	 	 	2.706,000.00	 	 	 	2.706.000.00	 	 	 	2.772,000.00	 
	  	 	$	25,310.982.36	 	 	$	39,917,137.42	 	 	$	65,228,119.78	 	 	$	65.228.119.78	 

 

* Capitalized Interest.

   

 

 

 

Exhibit B Cont.

	LEASE PAYMENTS
	 	 	 	 
	
Due Prior to

	  	
Annual Payment

	 
	 	 	 	 	 
	
09/01/12

	 	$	2,489,690.24	 
	
09/01/13

	 	 	3,482,355.82	 
	
09/01/14

	 	 	3,485,262.22	 
	
09/01/15

	 	 	3,484,324.82	 
	
09/01/16

	 	 	3,485,260.02	 
	
09/01/17

	 	 	3,481,779.42	 
	
09/01/18

	 	 	3,482,581.76	 
	
09/01/19

	 	 	3,484,929.76	 
	
09/01/20

	 	 	3,482,581.26	 
	
09/01/21

	 	 	3,480,859.76	 
	
09/01/22

	 	 	3,773,956.26	 
	
09/01/23

	 	 	3,775,006.26	 
	
09/01/24

	 	 	2,775,600.00	 
	
09/01/25

	 	 	2,775,325.00	 
	
09/01/26

	 	 	2,773,750.00	 
	
09/01/27

	 	 	2,775,250.00	 
	
09/01/28

	 	 	2,771,500.00	 
	
09/01/29

	 	 	2,772,500.00	 
	
09/01/30

	 	 	2,772,750.00	 
	
09/01/31

	 	 	2,772,000.00	 
	  	 	$	63,577,262.60	 

 

  

2Unassociated Document

 

EXHIBIT 10.9

Matter No. 09522

CRA Resolution No. 10-71

DEVELOPMENT AGREEMENT

THIS DEVELOPMENT AGREEMENT (the “Agreement”) is made by and between the WEST PALM BEACH COMMUNITY REDEVELOPMENT AGENCY, a body corporate and politic organized pursuant to Chapter 163, Florida Statutes (the “CRA”), with an address of 401 Clematis Street, West Palm Beach, Florida 33401, and DIGITAL DOMAIN HOLDINGS CORPORATION, a Florida corporation (“DDH” or “Developer”) with an address of 10521 SW Village Center Drive, Suite 201, Port St. Lucie, Florida 34987.

WITNESSETH:

WHEREAS, Chapter 163, Part III, Florida Statutes allows for the creation of a community redevelopment agency; and

WHEREAS, Chapter 163, Part III, Florida Statutes authorizes preparation of a community redevelopment plan; and

WHEREAS, the West Palm Beach Community Redevelopment Plan for the Expanded City Center Area, adopted on December 16, 1985 and restated on April 9, 2009 (“Plan”), promotes economic and redevelopment activity and recognizes the necessity of attracting businesses to the redevelopment area; and

WHEREAS, the Plan identifies as a goal that the CRA, in cooperation with private development interests, shall encourage a mixture of uses and activities which facilitate and stimulate economic growth in the Downtown/City Center Redevelopment Area; and

WHEREAS, the Plan further provides that the CRA shall cooperate with the City and Palm Beach County School Board to identify additional public educational facilities and/or structures within the Downtown/City Center Redevelopment Area; and

WHEREAS, the Plan states a variety of revenue sources shall be used to finance the redevelopment and revitalization of the Downtown/City Center CRA; and

WHEREAS, these revenue sources include tax increment financing, bonds and state or federal grants; and

WHEREAS, as authorized by Chapter 163, Part III, Florida Statutes, a community redevelopment agency can undertake and carry out community redevelopment and related activities within the community redevelopment area, which may include the disposal of any real property; and

  

1

  

WHEREAS, Chapter 163, Part III, Florida Statutes provides that when authorized or approved by resolution or ordinance of the governing body, a community redevelopment agency has power in its corporate capacity, in its discretion, to issue redevelopment revenue bonds from time to time to finance the undertaking of any community redevelopment under this part, including, the payment of principal and interest upon any advances for surveys and plans or preliminary loans, and has power to issue refunding bonds for the payment or retirement of bonds or other obligations and allows a community redevelopment agency the power to authorize the issuance of revenue bonds as set forth in Section 163.385, Florida Statutes; and

WHEREAS, Chapter 163, Part III, Florida Statutes enables a community redevelopment agency to borrow money, public or private, for the purposes of this part and to give such security as may be required and to enter into and cany out contracts or agreements in connection therewith; and

WHEREAS, moneys in the redevelopment trust fund may be expended from time to time for undertakings of a community redevelopment agency as described in the Plan including for the repayment of principal and interest or any redemption premium for loans, advances, bonds, bond anticipation notes, and any other form of indebtedness; and

WHEREAS, any county or municipality, to the greatest extent it determines to be feasible in carrying out the provisions of Section 163.345, Florida Statutes, shall afford maximum opportunity, consistent with the sound needs of the county or municipality as a whole, to the rehabilitation or redevelopment of the community redevelopment area by private enterprise; and

WHEREAS, by Resolution No. 05-65 adopted November 7, 2005, the CRA adopted the Strategic Finance Plan to identify initiatives to attract private investment to the Downtown/City Center Community Redevelopment Area; and

WHEREAS, the Strategic Finance Plan states that the City and CRA shall continue to recognize the importance of education and services provided by education partners in the community; and

WHEREAS, the Downtown/City Center CRA is established as a county wide and regional center for arts, culture and entertainment; and

WHEREAS, the property known as the “Tent Site Property” is identified in the Plan as a prominent development site and prime entryway on the corridor to the City; and

WHEREAS, the State of Florida Entertainment Industry Economic Development Bill, Florida House Bill 697, is a film incentive program which creates a film and digital media tax credit; and

WHEREAS, the Entertainment Industry Economic Development Bill allows the State of Florida to retain and create higher wage jobs by attracting production spending immediately, generate substantial amounts of new tax revenue, and boost ancillary businesses; and

  

2

  

WHEREAS, Digital Domain Holdings Corporation (“DDH”) and Florida State University (“FSU”) approached the CRA with an economic development proposal for the Tent Site Property; and

WHEREAS, the proposal for redevelopment of the Tent Site Property includes a minimum of 150,000 square feet of digital media, film, production and educational facilities to be occupied by FSU, DDH and the Digital Domain Institute (“DDI”); and

WHEREAS, the CRA has reviewed the DDH proposal and concurs it meets the goals and objectives of the Plan by providing an educational presence and attracting a new industry to the Downtown/City Center Redevelopment Area; and

WHEREAS, Section 163.380, Florida Statutes, provides that real property owned by the CRA shall be sold or otherwise transferred at a value to be determined to be in the public interest for uses in accordance with the Plan and further provides that the CRA shall take into account and give consideration to the long-term benefits to be achieved by the CRA resulting from inclining short-term losses or costs in the disposal of such real property, the uses provided in the Plan, the restrictions upon, and the covenants, conditions and obligations assumed by the purchaser and the objectives of the Plan for the prevention of the recurrence of slum or blighted areas; and

WHEREAS, on September 15, 2010, the CRA published a Notice of Intent to Dispose of the Tent Site Property in accordance with Florida Statutes, Chapter 163, Part III (“Notice”); and

WHEREAS, no proposals were received in response to the Notice; and

WHEREAS, by Resolution No. 10-70, the CRA has authorized a grant to DDH in the amount of Ten Million Dollars ($10,000,000) to offset a portion of the cost of the expansion of the FSU Film School in West Palm Beach (the “Grant Agreement”); and

WHEREAS, CRA and DDH desire to enter into a definitive agreement for the conveyance of the Tent Site Property and the financing, development, construction, operation and maintenance of the improvements (“Development Agreement”); and

WHEREAS, the CRA Board has conducted public meetings prior to approving this Agreement, made a finding of public purpose, and determined that approval of this Agreement is in the best interests of the CRA.

NOW THEREFORE, it is mutually covenanted and agreed by and between the parties hereto that the Agreement is made upon the terms, covenants and conditions hereinafter set forth.

  

3

  

ARTICLE I

DEFINITIONS

For all purposes of this Agreement, the following terms shall have the following meanings:

“Agreement” means, collectively, this Development Agreement and all exhibits and attachments hereto, as any of the same may hereafter be supplemented, amended, restated, severed, consolidated, extended, revised and otherwise modified, from time to time, either in accordance with the terms of this Agreement or by mutual agreement of the Parties.

“Board” means the governing body of the CRA.

“Chair” means the chairperson of the governing body of the CRA.

“City” means the City of West Palm Beach, Florida.

“City Center Redevelopment Area” shall mean the area described in the West Palm Beach Community Redevelopment Plan for the Expanded City Center Area adopted by the CRA on December 16, 1985, and restated on April 9, 2009, in accordance with Chapter 163, Part III, Florida Statutes, as amended from time to time.

“Certificate of Occupancy” or “CO” shall mean shall have the meaning set forth in Section 4.2.

“Closing” shall have the meaning set forth in Section 3.1.

“Concept Plan” shall have the meaning set forth in Section 4.3(b).

“Construction Commencement Date” shall have the meaning set forth in Section 4.2(a).

“Construction Completion Date” shall have the meaning set forth in Section 4.2(a).

 

“Construction Financing” shall have the meaning set forth in Section 4.6(a).

“CRA” means the West Palm Beach Community Redevelopment Agency.

“DDI” means Digital Domain Institute, a wholly owned subsidiary of Digital Domain Holding Corporation, and a first-of-its-kind accredited educational facility offering degree programs that are interwoven with an industry leading technology and entertainment company.

“Deed” shall have the meaning set forth in Section 3.1.

  

4

  

“Developer” or “DDH” shall mean Digital Domain Holdings Corporation, a Florida corporation.

“DRI” means the CityPlace Development of Regional Impact adopted by the City and approved by the State Department of Community Affairs and the Treasure Coast Regional Planning Commission, as amended from time to time.

“Due Diligence Period” shall have the meaning set forth in Section 2.4.

“Effective Date” shall have the meaning set forth in Section 2.1.

“FSU” shall mean Florida State University.

“FSU Film School” shall mean the FSU College of Motion Picture Arts.

“Grant Agreement” shall mean the Grant Agreement between the CRA and Developer of even date herewith, approved by Resolution No. 10-70.

“Improvements” or “Project” shall refer collectively to the Phase I Improvements and Phase II Improvements.

“Maximum Financing Amount” shall have the meaning provided in Section 4.6(b).

“Parking Facility” shall have the meaning set forth in Section 4.5.

“Partial Take Out Financing” shall have the meaning set forth in Section 4.6(b).

“Party” or “Parties” shall mean CRA and/or Developer.

“Phase I” or “Phase I Improvements” shall have the meaning set forth in Section 4.1.

“Phase  I  Parcel”  shall  have  the  meaning  set  forth  in  Section  4.1.

“Phase II” or “Phase II Improvements” shall have the meaning set forth in Section 5.1.

“Phase II Parcel” shall have the meaning set forth in Section 5.1.

“Plan” shall mean the West Palm Beach Community Redevelopment Plan for the Expanded City Center Area adopted by the CRA on December 16, 1985, and restated on April 9, 2009, in accordance with Chapter 163, Part III, Florida Statutes, as amended from time to time.

  

5

  

“Plans and Specifications” shall have the meaning set forth in Section 4.3(c).

“Post Closing Obligations” shall have the meaning set forth in Section 3.2.

“Property” shall have the meaning set forth in Section 2.2.

“Security Fund” shall have the meaning set forth in Section 4.6(d).

“SPE” shall have the meaning set forth in Section 3.5.

“Vertical Construction” shall have the meaning set forth in Section 3.4.

ARTICLE II

EFFECTIVENESS AND TERMINATION; PROPERTY;

DUE DILIGENCE PERIOD

2.1            Effectiveness and Termination. This Agreement shall be effective on the date executed by the later of CRA and Developer (“Effective Date”) and shall terminate upon the issuance of the Certificate of Occupancy for the Phase II Improvements, unless sooner terminated pursuant to the terms of this Agreement, and subject to all provisions of this Agreement which specifically survive any such termination of the Agreement.

2.2            Property. CRA hereby agrees to convey to Developer, and Developer hereby agrees to accept from CRA, subject to the terms and conditions hereinafter set forth, that certain property bounded by Okeechobee Boulevard, Lakeview Avenue, Dixie Highway and Quadrille Boulevard, in the City of West Palm Beach and consisting of approximately 2.36 acres, as more particularly described in Exhibit A attached hereto (“Property”) and any and all improvements located on the Property and owned by CRA.

2.3            As Is; Acceptance of Property. It is understood and agreed that, except as may be otherwise herein specifically provided, the CRA does not make, and specifically disclaims, any warranties or representations of any kind or character, express or implied, with respect to the Property, including but not limited to, (i) warranties or representations as to matters of title, (ii) zoning, (iii) tax consequences, (iv) physical or environmental conditions, (v) availability of access, (vi) ingress or egress, (vii) operating history or projections, (viii) valuation, (ix) governmental approvals, (x) governmental regulations, or (xi) any other matter or thing relating to or affecting the Property including, without limitation: (a) the value, condition, merchantability, marketability, profitability, suitability, or fitness for a particular use or purpose of the Property; (b) the manner or quality of the construction or materials incorporated into any of the Property; and (c) the manner, quality, state of repair or lack of repair of the Property. Developer agrees that with respect to the acquisition of the Property and development of the Project, it has not relied upon and will not rely upon, either directly or indirectly, any representation or warranty of the CRA or any employee, officer, or agent of the CRA, except as specifically set forth in this Agreement or in the Grant Agreement. Developer represents that it is a knowledgeable buyer of real estate and that it is relying solely on its own expertise; and that it will conduct such inspections and investigations of the Property, including, but not limited to, the physical and environmental conditions thereof, and shall rely upon same, and, upon Closing, shall assume the risk that adverse matters, including, but not limited to, adverse physical and environmental conditions, may not have been revealed by its inspections and investigations. Developer acknowledges and agrees that upon Closing, the CRA shall convey to the Developer and Developer shall accept the Property “as is, where is”, with all faults; and there are no oral agreements, warranties, or representations (except as herein specifically provided), collateral to or affecting the Property by the CRA, any agent of the CRA, or any third party. Developer further acknowledges that the CRA has no obligation to make repairs, replacements or improvements except as may otherwise be expressly stated herein. The terms and conditions of this section shall expressly survive the Closing and not merge or be incorporated into the Deed. The CRA is not liable or bound in any manner by any verbal or written statements, representations, or information pertaining to the Property furnished by the CRA, or any real estate broker, agent, employee, servant or other person, unless the same are specifically set forth herein or in the Grant Agreement.

  

6

  

2.4          Due Diligence.

a.            Due Diligence. Developer shall have a period of ninety (90) days after the Effective Date (the “Due Diligence Period”) to make its examination and inspection of the Property, including taking such soil and engineering tests, studies and samples and to otherwise inspect the Property to determine, in Developer’s sole and absolute discretion, whether the Property is suitable for Developer’s purposes. No invasive testing or boring other than customary soil tests and environmental assessments shall be done without prior notification to the CRA and CRA’s written authorization of the same. If Developer discovers any hydrocarbon substances, polychlorinated biphenyls, or any other hazardous or toxic substances, wastes or materials (as determined under federal, state or local law then in effect), asbestos or asbestos-bearing materials or other environmental condition subject to legal requirements for corrective action or otherwise affecting all or any portion of the Property, Developer shall immediately notify the CRA. The cost of Developer’s due diligence investigation as provided herein shall be borne solely by Developer. The CRA shall cooperate in providing to Developer any related Property information in the CRA’s possession as may be reasonably requested by Developer. Developer shall provide to the CRA copies of all due diligence reports prepared by or for Developer promptly upon the receipt or preparation of such reports.

b.            Access. Developer shall have the right to commence Developer’s inspection of the Property immediately after the Effective Date and after the CRA’s receipt of written evidence that Developer has procured the insurance required by subsection 2.4(c) of this Agreement. Developer’s physical inspection of the Property shall be conducted during normal business hours at times mutually acceptable to the CRA and provided that Developer shall not interfere or otherwise interrupt the parking operations on the Property. In the event that Developer has exercised all reasonable diligence to complete customary investigations of the Property during the Due Diligence Period but is unable to obtain sufficient access to the Property for such investigations and provides written notice to the CRA that Developer needs additional time to complete its due diligence, the CRA’s Chair shall have the right to grant a one time extension of the Due Diligence Period of no more than sixty (60) days.

  

7

  

c.            Insurance. Developer shall obtain or cause its consultants to obtain, at Developer’s sole cost and expense prior to commencement of any investigative activities on the Property, a policy of commercial general liability insurance covering any and all liability of Developer and the CRA with respect to or arising out of any investigative activities. Such policy of insurance shall be an occurrence policy and shall have liability limits of not less than One Million Dollars ($1,000,000.00) combined single limit per occurrence for bodily injury, personal injury and property damage liability. Such policy shall name the CRA and City as additional insureds and shall be in form and substance satisfactory to the CRA. In the event Developer’s activities on the Property, in the reasonable judgment of the CRA’s Risk Manager, indicate the need for additional insurance coverage or different types of insurance, Developer shall, upon request, obtain such insurance and provide CRA with evidence thereof.

d.            Indemnification. During the Due Diligence Period, Developer shall protect, indemnify, defend and hold the Property, CRA and CRA’s officers, employees, and agents free and harmless from and against any and all claims, damages, liens, liabilities, losses, costs and expenses, including reasonable attorneys’ fees and court costs (collectively “Liabilities”), resulting from Developer’s inspection and testing of the Property, including, without limitation repairing any and all damage to any portion of the Property, arising out of or related to (directly or indirectly) Developer’s inspections, surveys, tests and studies unless such Liabilities arise from the negligence of the CRA. Developer shall keep the Property free and clear of any mechanics’ liens or materialmens’ liens related to Developer’s right of inspection and the activities contemplated by this Agreement. This indemnification shall survive the conveyance of the Property to Developer and shall not be merged with the Deed (as defined herein) and shall survive any termination of this Agreement.

e.            Termination. If, prior to the expiration of the Due Diligence Period, Developer is not satisfied with respect to the Property for any reason, Developer may, in its sole and absolute discretion, terminate this Agreement upon written notification to the CRA (“Notice of Termination”), in which case this Agreement and the Grant Agreement shall be terminated and the Parties shall have no further liability or obligation hereunder except for those obligations which expressly survive termination.

f.            Signage. Within thirty (30) days of the expiration of the Due Diligence Period Developer shall install signage on the Property announcing its intended use.

  

8

  

2.5          Title; Survey.

a.           Title. Within sixty (60) days of the Effective Date, Developer shall obtain a title commitment (“Title Commitment”) for owner’s title insurance policy for the Property and shall deliver a copy of the Title Commitment to the CRA accompanied by one copy of all documents affecting the Property and which are set forth as exceptions on the Title Commitment. Prior to the Closing, Developer shall obtain an updated commitment to the original Title Commitment for the Property which shall show no new matter not disclosed in the initial Title Commitment as approved by Developer. Developer shall give CRA written notice (the “Title Notice”) prior to the expiration of the Due Diligence Period if Developer objects to any of the title exceptions. In the event Developer objects to any title exception(s), Developer shall state in the Title Notice which exception(s) set forth on the Title Commitment (or updated Commitment) are unacceptable and CRA shall use its best efforts to eliminate those exceptions. All title exceptions not timely objected to by Developer shall be deemed “Permitted Exceptions.” CRA shall furnish good and marketable title to the Property, subject only to the Permitted Exceptions. Upon receipt of the Title Notice, CRA shall attempt to eliminate or modify all unacceptable matters to the satisfaction of Developer. Developer may, at any time, waive in writing its objection to title and accept title to the Property subject to the exceptions objected to by Developer. In the event Developer does not waive its objections (as set forth in the Title Notice) and if CRA is unable to remove the matters within thirty (30) days after receipt of the Title Notice, Developer may, at its option (i) accept title subject to the objections raised by Developer, in which event said objection(s) shall be deemed waived for all purposes, or (ii) rescind this Agreement, whereupon this Agreement shall terminate. Developer shall elect one of the two options specified in the preceding sentence within five (5) business days after Developer receives notice from CRA that CRA is unable to remove such other exceptions objected to by Developer.

b.           Survey. Within sixty (60) days after the Effective Date, Developer, at its expense, may, as it deems appropriate, obtain an accurate boundary survey of the Property showing all recorded easements on the Property, calculating the area of the Property in acres and including the surveyor’s description of the Property. If the Survey shows any defects or matters unacceptable to Developer, including without limitation, any matter which would prevent the elimination of the survey exception from the Title Commitment, the same shall be treated as a title defect as provided in Section 2.5(a) above.

2.6          Reservation of Rights. The CRA reserves the right to continue to use the Property, and shall be entitled to retain all revenue generated by such use, until the Property is conveyed to Developer. After the date of conveyance of the Property, the CRA may continue to utilize the Property for public parking pursuant to a written lease agreement with Developer for $1 rent per year which lease shall provide (a) that claims arising out of the maintenance and operation of the public parking shall be the responsibility of the CRA; and (b) that Developer shall have the right to terminate the lease upon thirty (30) days written notice to the CRA at such time that Developer is ready to commence site work on the Property for construction of the Phase I Improvements. Without waiving the right to sovereign immunity as provided by Section 768.28, Florida Statutes, CRA acknowledges to be self-insured for General Liability under Florida sovereign immunity statutes with coverage limits of $100,000 Per Person and $200,000 Per Occurrence; or such monetary waiver limits that may change and be set forth by the legislature. When requested, CRA shall provide an affidavit or Certificate of Insurance evidencing insurance, self-insurance and/or sovereign immunity status, which Developer agrees to recognize as acceptable for the above mentioned coverages. Compliance with the foregoing requirements shall not relieve the CRA of its liability and obligations under this Agreement.

  

9

  

ARTICLE III

CONVEYANCE OF PROPERTY; POST CLOSING OBLIGATIONS

3.1          Closing; Deed. Conveyance of the Property shall occur within forty five (45) days after the expiration of the Due Diligence Period or the earlier satisfaction of the Due Diligence Period by written notice by Developer to the CRA acknowledging completion of its due diligence and waiver of its right to terminate (“Closing”). The Property will be conveyed at Closing to Developer for the sum of $10.00 by Special Warranty Deed in substantially the form attached hereto as Exhibit B (“Deed”). The Parties acknowledge and agree that the Deed shall incorporate, as a restrictive covenant, the terms and conditions of this Agreement. Developer shall be responsible for obtaining title insurance and paying for all closing costs except for the CRA’s or City’s attorneys’ fees, which shall be borne by the CRA or the City. At the Closing the CRA shall execute and deliver to Developer (a) the Deed; (b) a Seller’s affidavit in form and content as may be reasonably required by the title company to provide the gap coverage necessary to issue at Closing an endorsement to the Title Commitment deleting the standard gap exception, the standard mechanic’s lien exception and the standard parties in possession exception; (c) Non-foreign affidavit evidencing that Purchaser shall not be liable for transfer liability under Section 1445 of the Internal Revenue Code, as amended; and (d) a counterpart of the closing statement. Developer shall execute and deliver a counterpart of the closing statement.

3.2          Post Closing Obligations. Developer and CRA shall each use all reasonable efforts to satisfy their respective conditions set forth in this section (collectively, the “Post Closing Obligations”) by December 31, 2012 (as may be extended). Developer shall provide the CRA monthly with a written report describing the status of its efforts to satisfy its Post Closing Obligations.

a.            Developer shall obtain construction financing for no less than one hundred percent (100%) of the cost of construction for the Phase I Improvements, as evidenced by a written commitment from an institutional lender to finance the construction of the Phase I Improvements conditioned only upon those matters typically contained in a bank commitment letter (“Construction Financing”).

  

10

  

b.            Developer shall obtain all required governmental regulatory permits, including City foundation and demolition permits, approvals or other consents necessary to permit Developer to proceed with the Phase I Improvements including DRI Level III Site Plan Approvals from the City; provided, however that a building permit for vertical improvements from the City shall not be required to satisfy this condition. Developer shall be responsible for preparing and filing the documents required for all such approvals and for all costs and expenses of any such preparation and submittal. Such documents shall be submitted to CRA for review and approval prior to filing with the authorities. CRA acknowledges that time is of the essence for such review and approval. CRA shall in good faith cooperate with Developer’s request for approval of a Level III Site Plan(s) for the Property. Such applications shall be at Developer’s sole cost and expense. To the extent required by applicable law, CRA shall execute all necessary consents and applications for the same, provided such requests comply with the terms and conditions of this Agreement and all applicable laws, ordinances, codes and regulations.

c.            Developer shall enter into a contract with FSU to provide consulting services to Developer for the DDI program for a term of not less than ten (10) years from the date of issuance of the Certificate of Occupancy for Phase I.

d.            Developer shall have a written commitment from FSU to lease a minimum of 50,000 square feet of Phase I for the FSU Film School for a minimum of ten (10) years commencing upon the date of issuance of the Certificate of Occupancy for Phase I.

e.            The CRA shall cause the abandonment and/or vacation of the fourteen foot (14’) alley bisecting the Property as identified on the sketch attached hereto as Exhibit C (“Alley”). Notwithstanding the foregoing, the abandonment of the Alley shall be subject to (i) the Utility Easement dated December 2, 1998 and recorded at ORB 10788, Page 448; and (ii) existing utilities located in the Alley. Any utilities located in the Alley, if any, shall be relocated by Developer at its sole cost and expense.

3.3          Satisfaction of Post Closing Obligations. Upon satisfaction of Developer’s Post Closing Obligations set forth in subsections 3.2(a) – 3(d), Developer shall provide written notice to the CRA and shall provide documentation evidencing the satisfaction of the same.

3.4          Reverter. The Deed shall provide that (a) in the event Developer does not satisfy the Post Closing Obligations by December 31, 2012 (as may be extended in accordance with Section 3.6), or (b) commence Vertical Construction of the Phase I Improvements by December 31, 2013 (as such date may be extended in accordance with Section 3.6), then, all right, title and interest in and to the Property shall automatically revert to the CRA. “Vertical Construction” shall be defined as setting the first column to raise the new building structure and shall not include work associated with a demolition or foundation permit. The Parties acknowledge and agree that Article VIII shall not apply to the reverters provided for in this Section.

  

11

  

3.5           Single Purpose Entity. CRA acknowledges and agrees that Developer shall be permitted to create a wholly owned single purpose entity (“SPE”) to hold title to, develop and operate the Property, and that DDH may assign any and all rights it possesses hereunder to a SPE, provided that (a) the Deed into such SPE shall contain the reversionary interests to the CRA described in Section 3.4 hereof, and (b) Developer unconditionally guarantees the full and timely performance by the SPE of all duties to be performed and covenants to be fulfilled by Developer under this Agreement, the Grant Agreement or any other agreement entered into between Developer and CRA related to the Property and the continuing accuracy of all representations and warranties made by Developer set forth in this Agreement, the Grant Agreement or any other agreement entered into between Developer and CRA related to the Property. In the event of any breach of or non performance under the Agreement, the Grant Agreement or any other agreement entered into between Developer and CRA related to the Property, the CRA may, in its sole election, proceed directly against Developer on the above guarantee without joining SPE as a party. In the event of any dispute with the CRA, Developer hereby waives any corporate form, identity of parties, or similar organizational structure defense it might have as guarantor of the performance of SPE under the Agreement, the Grant Agreement or any other agreement entered into between Developer and CRA related to the Property. CRA and Developer expressly acknowledge and agree that the option for Developer to hold title to, develop, and operate the Property through a SPE shall not in any way relieve Developer of any of its obligations to CRA contained in this Agreement or the Grant Agreement.

3.6           Extensions. If requested by Developer, CRA may extend the times for performance set forth in subsections 3.2(a) - (d) in increments up to three (3) months, provided that Developer is using commercially reasonable efforts to satisfy its performance obligations. Such extensions shall be set forth in amendments to the Agreement, are subject to the reasonable approval of the CRA Board and shall not exceed a collective total of twelve (12) months for all extensions authorized by CRA. Any extensions granted by the CRA shall automatically extend all subsequent deadlines established herein by the same amount of time, including, without limitation, the time frames set forth in Section 3.4 herein.

3.7           Obligation to Record. The Parties agree that at Closing this Agreement shall be recorded in the Official Records of Palm Beach County and that the Deed shall incorporate, as a restrictive covenant, the terms and conditions of this Agreement.

ARTICLE IV

PHASE I

4.1           Phase I Improvements. Developer shall construct, at its sole cost and expense, on a mutually agreed upon portion of the Property, the legal description for which shall be determined upon approval of the DRI Level III Site Plan and attached hereto as Exhibit D (“Phase I Parcel”) a minimum of 150,000 total square feet (excluding parking) in improvements (“Phase I Improvements”). The Phase I Improvements shall include approximately (a) 50,000 square feet to be occupied by FSU for use by FSU’s Film School for its major focused on emerging motion picture media and for its Torchlight Program (“FSU Improvements”); (b) 50,000 square feet for DDI for an educational program committed to digital technology, and (c) 50,000 square feet for a DDH production facility. For any additional leasable space in Phase I, if any, Developer shall use commercially reasonable efforts to recruit and secure tenants that are connected to the digital media or entertainment industry.

  

12

  

4.2          Construction Obligations.

a.            Developer shall: (i) commence Vertical Construction of the Phase I Improvements (such date of commencement being defined as the “Construction Commencement Date”) by December 31, 2013; and (ii) proceed diligently and continuously with the development and construction of the Phase I Improvements so that a certificate of occupancy (“Certificate of Occupancy”) for the Phase I Improvements is received by no later than December 31, 2014 (“Construction Completion Date”). Notwithstanding the foregoing, in the event Developer does not receive its Certificate of Occupancy by June 30, 2014, for each day from July 1, 2014 until issuance of the Certificate of Occupancy, Developer shall pay to the CRA an amount equal to the revenue that would have been received by the CRA from the City if the Certificate of Occupancy had been issued on June 30th, 2014 and the Property was assessed as of January 1, 2014. In such event, Developer and CRA shall calculate, and Developer shall pay quarterly commencing July 1, 2014, the temporary revenue amounts due using the millage rate then in effect and the assessed value per square foot of City Tower as a proxy for the future assessed value of the completed Phase I Improvements. Within thirty (30) days after the Certificate of Occupancy for Phase I is issued and Phase I is assessed by the Palm Beach County Property Appraiser, Developer and CRA shall “true up” the revenue payments for the temporary period from July 1, 2014 until issuance of the Certificate of Occupancy.

b.            Developer shall construct the Phase I Improvements in accordance with the Plans and Specifications, as defined below, and in a good and workmanlike manner, free of liens and defects, utilizing the quality and materials of construction generally utilized for a project comparable in scope, magnitude and location.

c.            Developer will: (i) ensure that sufficient manpower and materials are deployed throughout the development and construction of the Phase I Improvements, (ii) proceed with all necessary diligence towards the completion of the development and completion of the Phase I Improvements, and (iii) not abandon or otherwise terminate the development and construction of the Phase I Improvements.

d.            Developer shall construct Phase I in accordance with the DRI and all other laws, rules, regulations, orders, codes, and requirements of all governmental authorities having jurisdiction over Developer or the Property (“Requirements”). Developer shall be responsible for timely payment of all applicable permitting, licensing, utility connection and similar fees and charges in connection with the design and construction of the Phase I Improvements.

e.            Developer shall construct the Improvements to meet the United States green building Council (USGBC) Leadership in Energy and Environmental Design (LEED) rating system, the green building Initiative’s green Globes rating system, the Florida green building Coalition standards, Environmental Protection Agency’s EnergyStar, International Code Council’s Green Building Code, or a nationally recognized, high-performance green building rating system. Certification by one of the above rating systems is not mandatory, however, demonstrated evidence of compliance to their minimum standard shall be provided to the CRA.

  

13

  

 

4.3          Design and Construction Review Procedures.

a.            Developer acknowledges that the Property is the gateway to the City and that the City and CRA expect any Improvements to be iconic. As such, in addition to the City’s regulatory process, CRA shall have the right to review and approve the Plans and Specifications, as defined below, for the exterior architectural design and construction of the Phase I Improvements.

b.            Developer shall submit a concept plan (“Concept Plan”) and an estimate of the total project costs for the Phase I Improvements to the CRA. The Concept Plan shall include conceptual drawings, architectural renderings, exterior elevations, facades, proposed site and landscaping plans and a narrative description of the design and construction standards and materials proposed for the exterior finishes and appearances. The CRA shall have forty-five (45) days after receipt thereof to approve or disapprove the Concept Plan. Notwithstanding the foregoing, CRA shall not require changes to the design that will increase the total project costs (including soft costs, hard costs, tenant improvements, financing, etc.) above 5% of the total project cost as submitted by the Developer with the Concept Plan, or that will negatively impact the functionality of the Improvements. If the CRA disapproves the Concept Plan, Developer shall be given written notice of such disapproval setting forth the reason(s) for such disapproval. The Concept Plan, or any portion thereof, shall be resubmitted for approval within thirty (30) days of such disapproval. Developer acknowledges that the CRA’s review and approval of the plans is not limited to governmental requirements and may include reasonable subjective considerations relating to the overall visual appearance of the Project.

c.            The schematic plans (“Schematic Plans”), design development plans and construction plans (collectively, the “Plans and Specifications”) for Phase I and Developer’s construction of the Phase I Improvements shall be substantially in accordance with the approved Concept Plan. Developer shall not proceed with design or construction of any aspect of Phase I which materially deviates from the approved Concept Plan without first obtaining the CRA’s written approval. Whether or not any approval by the CRA is required, Developer shall submit to the CRA true, correct and complete copies of the Schematic Plans and the Plans and Specifications, and any material amendments or modifications thereto, promptly following their preparation. In the event of termination of this Agreement prior to completion of construction of the Phase I Improvements, all Plans and Specifications relating to the Phase I Improvements will become the property of the CRA without restriction or limitation on their use. Any reuse of Developer’s Plans and Specifications by CRA in such event will be at no additional cost to the CRA or Developer, shall be at CRA’s sole risk, and Developer shall not be liable to CRA or any other entity in connection with any such use of the Plans and Specifications. Developer shall deliver to the CRA a final development budget after the bidding of construction contracts including an itemization of all costs allocated to the construction of the FSU Improvements.

  

14

  

d.           In no event shall the CRA or the City have any liability in connection with the construction or operation of the Property as a result of or arising from any approvals relating thereto given or withheld (or the right to give or withhold such approvals) pursuant to this Agreement, or a result of or arising from any other right to review, comment on or evaluate any plans, drawings, specifications or other documents in connection with the construction or operation of the Improvements. In no event shall any such review, approval, comment or evaluation by the CRA relieve Developer of any liability or responsibility under this Agreement, it being understood and agreed that the CRA is at all times ultimately relying on Developer’s skill, knowledge and professional training and experience in preparing (or causing the preparation of) any plans, drawings, specifications or other documents.

e.           Developer shall notify the CRA in writing of the names of all architects, engineers, construction contractors, project managers and other design and construction consultants engaged by Developer in connection with the design and construction of the Improvements (collectively the “Project Design and Construction Contractors”). The CRA shall have no right of approval with respect to any such engagement; provided, however, that Developer covenants and agrees that all Project Design and Construction Contractors shall have experience with the type of project being undertaken and shall be duly licensed to practice under the laws of the State of Florida.

f.           Prior to commencement of construction of the Phase I Improvements, Developer shall obtain, or cause each of its construction contractors who are acting as general contractors to obtain, payment and performance bonds, insuring the performance of the completion of the Phase I Improvements, acceptable in all respects to the CRA from a corporate surety authorized to do business in the State of Florida, reasonably acceptable to the CRA, and naming the City and CRA as dual obligees.

4.4          Principal Members; Project Administration

a.            Developer hereby designates Christina Dixon as the “Developer’s Project Representative” to represent Developer in all of its dealings with the CRA and City relating to the construction of the Phase I Improvements.

b.            The CRA shall take all actions necessary to ensure that a City/CRA project team is formed to assist Developer in expeditious completion of development and construction of the Phase I Improvements. The project team will include staff from Planning & Zoning, Engineering, Public Utilities, Construction Services and the Office of the City Attorney. Within thirty (30) days after execution of this Agreement, the CRA will designate a senior administration official (“CRA’s Project Representative”) as the primary point of contact for Developer and Developer’s representatives, agents, and contractors to interact with regarding all matters relating to the Property and the development and construction of the Phase I Improvements.

  

15

  

c.            Principal Members. In addition to the designation of Developer’s Project Representative, Developer shall assign and direct principal members to the development and implementation of the Improvements. Specifically, in furtherance thereof, both John Textor and Jonathon Teaford, or their equivalent replacements (“Principal Members”), will each devote substantial portions of their professional time to the performance of Developer’s obligations under this Agreement.

d.            Project Administration. The CRA’s Project Representative and Developer’s Project Representative shall meet regularly with each other and with other representatives of the Parties throughout the construction of the Improvements with the frequency and scope of such meetings to be determined mutually by the Parties’ Project Representatives, in their reasonable judgment, based on the then-current status of the Project. Developer shall provide the CRA with periodic written reports and briefings concerning the status of its performance of obligations under this Agreement including without limitation design and construction activity.

4.5          Parking Facility. The Phase I Improvements shall include a parking structure for use by tenants (“Parking Facility”). Developer shall, upon request by the City or CRA, evaluate the feasibility of opening the Parking Facility to the public at times that the Parking Facility is not being used by the Phase I tenants. Developer further agrees that in the event that it elects to open the garage to the public and contract with a parking garage operator to operate the Parking Facility, that it shall give the CRA a right of first refusal to operate the Parking Facility pursuant to commercially reasonable terms of a negotiated parking management agreement.

4.6          Financing for Phase I Improvements.

a.            Construction Financing. Developer shall be responsible for securing construction financing for the construction of the Phase I Improvements (“Construction Financing”).

b.            Partial Take Out Financing. The Parties have agreed that, at Developer’s option, a portion of the construction costs incurred in connection with the development and construction of Phase I (the “Partial Take Out Financing”) will be financed, upon completion of Phase I, by the CRA. At least one hundred twenty (120) days prior to the anticipated receipt of the Certificate of Occupancy for the Phase I Improvements, Developer shall provide written notice to CRA specifying the anticipated date of issuance of the Certificate of Occupancy and the amount of Partial Take Out Financing desired. Upon receipt of the notice, the CRA shall use its best efforts to initiate the process to issue the Partial Take Out Financing provided that the Partial Take Out Financing shall not in any event exceed the Maximum Financing Amount. The “Maximum Financing Amount” (i) shall not exceed Fifteen Million Dollars ($15,000,000) plus a debt service reserve, if required, and shall be inclusive of the CRA’s and Developer’s financing costs incurred through construction attributable to the amount equal to the Partial Take Out Financing, cost of issuance, and Developer’s cost for a CRA representative to review the Phase I plans, specifications, budgets and invoices; (ii) shall not be greater than the amount of the senior loan; and (iii) shall not in any event exceed thirty percent (30%) of Developer’s total project costs for the Phase I Improvements. Any costs and expenses of the Phase I construction project in excess of the Maximum Financing Amount shall be the sole responsibility of Developer. “Construction Costs” shall be defined as hard and soft construction costs and tenant improvements. The Partial Take Out Financing shall be structured and sold as determined by the CRA, in its sole discretion, in accordance with federal and state law and is expected to be in the form of taxable financing. Notwithstanding anything herein to the contrary, Developer shall have the right to secure its own permanent financing or to extend the term of its Construction Financing and, in such event, shall provide written notice to the CRA of such election and rejection of the CRA’s Partial Take Out Financing. The CRA shall have no obligation to close on the Partial Take Out Financing unless and until the Certificate of Occupancy is issued for the Phase I Improvements. The CRA shall use commercially reasonable efforts to obtain the most favorable terms for the Partial Take Out Financing available to the CRA and agrees that the minimum term of the Partial Take Out Financing shall be twenty (20) years unless otherwise agreed to by Developer.

  

16

  

c.            Loan Terms. Developer shall pay to the CRA: (i) the debt service on the Partial Take Out Financing, (ii) amounts necessary to replenish any debt service and other reserves relating to the Partial Take Out Financing, (iii) amounts necessary to reimburse the CRA and/or the City, if applicable, for payments made by either in connection with the Partial Take Out Financing, and (iv) any other amounts due in connection with the Partial Take Out Financing. The loan shall be paid as set forth in agreements to be entered into between the CRA and Developer with respect to the Partial Take Out Financing, including but not limited to a promissory note, and shall be secured by a second mortgage on the Phase I Parcel that is subordinate to not more than $35 million in senior loans, a security fund as described in subsection (d) below, an Assignment of Leases and Rents as described in subsection (e) below, a personal guarantee of repayment of the Partial Take Out Financing by John Textor (the “Guarantee”) as described in section (g) below, and key man insurance as described in subsection (f) below. CRA agrees to subordinate its subordinate mortgage interest to any future refinance or modification of the first mortgage debt by Developer provided that the outstanding amount of the first mortgage debt is not increased. The repayment schedule set forth in the loan agreement shall provide for monthly payments to the CRA and shall be structured to require that Developer makes sufficient payments to the CRA so that the CRA will have one hundred percent of the funds needed to meet the CRA’s debt obligations no less than thirty (30) days prior to the payment due date.

d.            Security Fund. Commencing on the issuance of the Partial Take Out Financing, Developer shall pay to the CRA an additional payment equal to 1/12th of the maximum annual debt service on the Partial Take Out Financing. The payment shall be paid annually on the anniversary of the issuance of the Partial Take Out Financing, until the equivalent of the maximum annual debt service on the Partial Take Out Financing has been received as a security fund to secure Developer’s performance of the repayment of the Partial Take Out Financing. Developer’s obligation to pay the annual security payment shall cease upon the receipt by the CRA of an amount equal to the maximum annual debt service on the Partial Take Out Financing provided however that Developer shall have a continuing obligation to replenish the Security Fund in the event that the CRA withdraws funds to pay Developer’s debt service obligations. CRA may elect to use the funds to pay the debt service payments on the Partial Take Out Financing due in the final year of the loan. Within thirty (30) days after the payoff of the Partial Take Out Financing, CRA shall pay to Developer any funds remaining the Security Fund, including any interest earned on the deposits remaining in the Security Fund.

  

17

  

e.            Assignment of Rents and Leases. Upon issuance of the Partial Take Out Financing as provided for in Section 4.6 hereof, Developer shall execute and deliver to CRA an Assignment of Rents and Leases granting CRA a second priority security interest in the rental income, but not in CAM or other charges, generated by the tenants of Phase I, as additional collateral for the repayment by Developer of the Partial Take Out Financing. Such security interest shall be subordinated to not more than $35 million in senior financing. Upon Developer’s payoff of the Partial Take Out Financing, CRA shall record a Termination of the Assignment of Rents and Leases. Developer shall also provide CRA with a second priority security interest in such other collateral that may be situated at the Property and serving as security for the senior loan.

f.            Key Man Insurance. Prior to the closing of the Partial Take Out Financing, Developer shall deliver to CRA, as additional security for the repayment of the Partial Take Out Financing, a key man insurance policy, insuring the life of John Textor, in an amount not less than the equivalent of three years of the maximum annual debt service. The City and CRA shall be named as beneficiaries to the policy.

g.            Guaranty. Prior to the issuance of the Partial Take Out Financing, Developer shall deliver to the CRA a Guaranty executed by John Textor, in the form attached as Exhibit E (“Guaranty”) wherein Mr. Textor personally guarantees the repayment of the Partial Take Out Financing. The CRA shall have no obligation to issue the Partial Take Out Financing unless and until it receives the executed Guaranty. The parties acknowledge and agree that if delivered the Guaranty will terminate immediately and automatically upon Developer’s payoff of the Partial Take Out Financing.

ARTICLE V

PHASE II IMPROVEMEMTS

5.1          Phase II Improvements. Within five (5) years from the issuance of the Certificate of Occupancy for the Phase I Improvements, Developer shall commence Vertical Construction of the Phase II Improvements, at its sole cost and expense, on the remaining portion of the Property, the legal description for which shall be determined upon approval of the Level III Site Plan for Phase I and attached hereto as Exhibit F (“Phase II Parcel”). The “Phase II Improvements”, excluding parking, shall have a minimum square footage of 500,000 total square feet reduced by the amount of the total square footage, excluding parking, of the Phase I Improvements.

  

18

  

5.2           Design Approval. Developer acknowledges that the Property is the gateway to the City and the CRA and the City expect any development on the Property to be iconic. As such, in addition to the City’s regulatory approval process, the CRA shall have the right to review and approve the plans for the design and construction of the Phase II Improvements, including landscaping, in accordance with the Design and Construction Review Procedures set forth in Section 4.3. Notwithstanding the foregoing, CRA shall not require changes to the design that will increase the total project costs (including soft costs, hard costs, tenant improvements, financing, etc.) by more than five percent (5%) above the total project costs set forth in the project cost budget, or that will negatively impact the functionality of the Phase II Improvements.

5.3           Tenant Restrictions. For a period of five (5) years from the initial lease up of Phase II, not more than twenty percent (20%) of the initial leases for leased space in Phase II shall be leased to non-profit tenants or tenants moving from within a five (5) mile radius from the Property and within the City limits without the prior written consent of the CRA’s Chair, which consent shall not be unreasonably withheld. At the CRA’s request, Developer shall provide to the CRA a schedule of all leases, giving the names of all tenants, a description of the space leases and such other information as the CRA reasonably may request.

5.4           Failure to Construct. In the event that Developer does not commence Vertical Construction of Phase II within five (5) years from the issuance of the Certificate of Occupancy for the Phase I Improvements, Developer shall elect to either (a) pay to the CRA, as liquidated damages but not as a penalty, the sum of Three Million Dollars ($3,000,000); or (b) convey the Phase II Parcel to the CRA. Developer shall notify the CRA of its election on or before the 5th anniversary of the Phase I Certificate of Occupancy and such payment or reconveyance shall occur within thirty (30) days thereafter.

5.5           Prohibition on Transfer. Developer acknowledges that the CRA is conveying the Property to Developer as an economic incentive to encourage development of the Project by Developer. Therefore, as a portion of the consideration for the conveyance of the Property, Developer agrees that until the earlier of (a) the expiration of nine (9) years from the issuance of the Certificate of Occupancy for the Phase I Improvements, or (b) the issuance of the Certificate of Occupancy for the Phase II Improvements, Developer may not sell, assign, transfer or convey the Phase II Parcel to an unrelated third party in an arms-length transaction except in the following circumstance: Developer must pay to the CRA fifty percent (50%) of the amount by which the sales price for the Phase II Parcel exceeds the value of $95.00 per square foot as determined by the appraisal dated September 27, 2010 prepared by Anderson & Carr, Inc. and that the Phase II parcel may not be sold for less than fair market value as determined by a current appraisal. To establish the fair market value for Phase II, Developer and CRA each shall obtain an appraisal from a member of the MAI. If the two appraised values are within 25% of each other, fair market value will be the average of the two values. If not, a third appraisal shall be performed by an appraiser agreeable to both parties, and fair market value shall be the average of the three values. Each party shall bear the expense of the appraisal it commissions, and shall contribute 50% of the cost of the third appraisal, if any. The provisions of this Section 5.5 shall survive the Closing and shall be set forth in the Deed.

  

19

  

5.6           Extension of Prohibition on Transfer. If Developer is unable to secure a Replacement Educational Tenant, as required in Section 2.04 of the Grant Agreement, the terms of which are incorporated herein, the restriction of transferring the Property set forth in Section 5.5 above shall be extended from nine (9) years after the issuance of the Certificate of Occupancy for the Phase I Improvements to twenty (20) years.

ARTICLE VI

INDEMNIFICATION; LIMITATION OF LIABILTY

6.1           Indemnification. Developer shall indemnify, defend and hold harmless the CRA and City, and their respective employees, officials and agents (collectively, “Covered Persons”) from and against any and all claims, liabilities, expenses, losses, costs, damages, fines, penalties and causes or action of any kind and character, including attorneys’ fees, incurred or suffered by a Covered Person which is due to any act or omission of Developer arising as a result of (a) the acts or omissions of Developer or Developers officers, employees, agents under this Agreement; (b) the negligent or willful misconduct of Developer, Developer’s officers, employees or agents, or (c) the violation of federal, state, county or municipal laws, ordinances or regulations by Developer. This indemnification includes any costs, attorneys’ fees, expenses and liabilities incurred in the defense of any such claims or the investigation thereof. Developer agrees to pay all claims and losses and shall defend all suits, in the name of the CRA, its employees, and officers, including but not limited to appellate proceedings, and shall pay all costs, judgments and attorneys’ fees which may issue thereon. CRA reserves the right to select its own legal counsel to conduct any defense in any such proceeding and all costs and fees associated therewith shall be the responsibility of Developer under this indemnification provision. To the extent considered necessary by the CRA, any sums due Developer under this Agreement or the Grant Agreement may be retained by CRA until all of CRA’s claims for indemnification have been resolved, and any amount withheld shall not be subject to the payment of interest by CRA. This indemnification agreement is separate and apart from, and in no way limited by, any insurance provided pursuant to this Agreement or otherwise. The parties mutually acknowledge that the provisions of §725.08, Fla. Stat., have been fulfilled and govern this provision. This paragraph shall not be construed to require Developer to indemnify the CRA for its own negligence, or intentional acts of the CRA, its agents or employees. This clause shall survive the expiration or termination of this Agreement.

6.2           Limitation of Liability. The CRA desires to enter into this Agreement only if in so doing the CRA can place a limit on the CRA and City’s liability for any cause of action for money damages due to an alleged breach by the CRA of this Agreement, so that its liability for any such breach never exceeds of $100,000.00. Developer hereby expresses its willingness to enter into this Agreement with a $100,000.00 limitation on recovery for any damage action for breach of contract. Accordingly, Developer hereby agrees that neither the CRA nor City shall be liable to Developer for damages in an amount in excess of $100,000.00 for any action for breach of contract arising out of the performance or nonperformance of any obligations imposed upon the CRA by this Agreement. The foregoing provisions shall not preclude an action by Developer for specific performance. Nothing contained in this subsection or elsewhere in this Agreement is in any way intended to be a waiver of the limitation placed upon the CRA’s liability as set forth in Florida Statutes, Section 768.28.

  

20

  

ARTICLE VII

TAXES; MAINTENANCE

7.1          Taxes. From and after the Closing, Developer shall pay all ad valorem real property taxes and assessments, general and special, levied or assessed by a lawful authority against all or any portion of the Property. In the event that any portion of the Property is determined to be exempt from ad valorem real property taxes, Developer shall pay to the CRA an annual payment in lieu of taxes equal to the revenue CRA would have received had such portion of the Property not been determined to be tax exempt. Such payment amount shall be calculated using the proportional square footage of the tax exempt space, the millage rate then in effect, and an assessed value on the tax exempt space based on the assessed value of the Property. Developer shall also pay all intangible personal property taxes and assessments on the furniture, fixtures, inventory and equipment, and other property located on the Property and all sales tax assessed by the State of Florida or any other governmental authority.

7.2          Maintenance. Developer shall maintain the Property and the Improvements in a good, safe first class condition consistent with Class A office space.

ARTICLE VIII

DEFAULTS AND REMEDIES

8.01        Events of Default. The occurrence of any one or more of the following events shall constitute a Default hereunder:

	
  

	
a.

	
Failure by Developer to complete Phase I by December 31, 2014, as such date may be extended.

	
  

	
b.

	
In the event Developer fails to commence Vertical Construction of the Phase II Improvements in accordance with Section 5.4, failure to pay $3,000,000 or reconvey the Phase II Parcel to the CRA.

	
  

	
c.

	
If Developer makes or suffers any transfer of the Property except as permitted under Section 5.5.

	
  

	
d.

	
failure to observe or perform in any material respect any covenant, obligation or agreement contained herein or in the Grant Agreement.

  

21

  

	
  

	
e.

	
The material breach of any representation or warranty by either Party contained in this Agreement or the Grant Agreement if such material breach is not cured after written notice from the non-defaulting Party to the defaulting Party and a reasonable opportunity to cure such material breach.

	
  

	
f.

	
The filing by Developer of a petition to have Developer adjudged bankrupt or a petition for reorganization under any law relating to bankruptcy; or the appointment of a trustee or receiver to take possession of all or substantially all of Developer’s assets where such possession is not restored to Developer within ninety (90) days of such appointment.

8.2          Cure Period. In the event of a Default the non-defaulting Party shall provide written notice to the defaulting Party and the defaulting Party shall have thirty (30) days to cure such Default, provided that the cure period shall be extended if the Default cannot reasonably be cured within thirty (30) days and the defaulting Party is using commercially reasonable efforts to cure said Default.

8.3          Remedies for Default. Following the occurrence of a Default and the expiration of any applicable cure period, the non defaulting party may terminate this Agreement and the Grant Agreement. Additionally, the non-defaulting party shall have the right to have provisions of this Agreement enforced by any court having equity jurisdiction it being acknowledged that any such Default will cause irreparable injury to the non defaulting party and that money damages will not provide an adequate remedy.

ARTICLE IX

REPRESENTATIONS

9.1          Developer’s Representations. Developer represents and warrants that:

a.            Developer has been duly incorporated, is validly existing as a corporation under the laws of the State of Florida and is in good standing under the laws of the State of Florida.

b.            Developer has full corporate power to conduct its operations and has full corporate power to enter into this Agreement and to carry out all of the terms and conditions hereof.

c.            This Agreement has been duly authorized, executed and delivered by Developer and constitutes a valid and binding agreement of Developer, enforceable against Developer in accordance with its terms.

d.            Developer is, and after consummation of the transaction contemplated in this Agreement, will be able to realize upon its assets and pay its debts and liabilities, contingent liabilities and other commitments as they mature in the normal course of business.

  

22

  

e.            No proceeding looking toward merger, amalgamation, consolidation, liquidation or dissolution of Developer, or the sale or all or substantially all of the assets of Developer is pending or contemplated.

f.            Developer has no obligation or indebtedness that would impair its ability to fulfill the terms of this Agreement.

g.            No legal or governmental proceedings or investigations are pending, or, to the actual knowledge of Developer, threatened to which Developer is a party or to which the property of Developer is subject except for such proceedings or investigations which would not reasonably be expected to materially impact the ability of Developer to perform its obligations under this Agreement.

h.            Developer possesses all certificates, authorizations and permits issued by the appropriate federal, state, or local regulatory authorities necessary to conduct its operations.

i.            Developer has provided to the CRA audited financial statements and disclosures and CRA acknowledges that they have received these documents; such audited financial statements and disclosures are true and complete in all respects and fairly represent the financial position and results of operations of Developer in accordance with generally accepted accounting principles applied consistently, and no events or transactions have occurred subsequent to the date of the audited financial statements that would require adjustment to or disclosure in the audited financial statements; and there are no material liabilities or gain or loss contingencies that are required to be accrued or disclosed in the audited financial statements. Developer acknowledges that the CRA has relied on such audited financial statements and disclosures in its decision to enter into this Agreement.

j.           The financial projections provided by Developer to the CRA accurately represent Developer’s business intentions and are reasonable estimates of future performance based upon Developer’s knowledge and experience about past and current events and assumptions about conditions that Developer expects to exist and courses of action Developer expects to take. Developer acknowledges that the CRA has relied on such financial projections in its decision to enter into this Agreement and undertake its obligations hereunder or pursuant to this Agreement.

9.2          CRA’s Representations. CRA represents and warrants that:

a.           The CRA is a body corporate and politic organized pursuant to Chapter 163, Florida Statutes.

  

23

  

   

b.           The CRA has all requisite power and authority to enter into this Agreement and to carry out all the terms and provisions hereof.

 

c.           This Agreement has been duly authorized by all necessary action of the Board of Commissioners, executed and delivered by the CRA and constitutes a valid and binding agreement of the CRA.

 

9.3           Conflict of Interest. Developer represents and warrants that, to the best of its actual knowledge, no member, official or employee of the CRA, the City or any other governing body has any direct or indirect financial interest in this Agreement, nor has participated in any decision relating to this Agreement that is prohibited by law. Developer represents and warrants that, to the best of its knowledge, no officer, agent, employee or representative of the CRA, the City or any other governing body has received any payment or other consideration for the making of this Agreement, directly or indirectly from Developer. Developer represents and warrants that it has not been paid or given, and will not pay or give, any third person any money or other consideration for obtaining this Agreement, other than normal costs of conducting business and costs of professional services such as architects, engineers and attorneys. Developer acknowledges that the CRA is relying upon the foregoing representations and warranties in entering into this Agreement and would not enter into this Agreement absent the same.

 

9.4           No Brokers. The CRA and Developer each represents and warrants to the other that such party has not authorized or employed, or acted by implication to authorize or to employ, any real estate broker or salesman to act for such party in connection with this Agreement.

                             

ARTICLE X 

GENERAL PROVISIONS

 

10.1        Prohibition on Assignment. Except for the creation of a SPE in accordance with Section 3.7 hereof, Developer shall not transfer or delegate (by sale, assignment, pledge, license or otherwise) all or any of its interest or rights under this Agreement except with the prior written consent of CRA, which may be withheld in its sole discretion. Any such transfer or delegation made without CRA’s consent shall be void and ineffective and shall constitute a default by Developer under this Agreement.

 

10.2        Impact Fees. Developer shall pay any and all fees assessed or imposed by any state, county or local governmental or quasi-governmental body, agency or political subdivision in connection with any construction work contemplated hereby.

 

10.3        Complete Agreement. There are no oral agreements between CRA and Developer affecting this Agreement, and this Agreement supersedes and cancels any and all previous negotiations, arrangements, agreements, letters of intent and understanding, between CRA and Developer.

 

  

24

  

 

10.4        Compliance with Laws. Developer, at its sole cost and expense, shall promptly comply with all laws, statutes, ordinances and governmental rules, regulations or requirements now in force or which may hereafter be in force; with the requirements of any board of fire underwriters or other similar body now or hereafter constituted; with any direction or occupancy certificate issued pursuant to any law by any public officer or officers; and with the provisions of all recorded documents affecting the Property (including, without limitation, any ground agreement, mortgage or covenants, conditions and restrictions), insofar as any thereof relate to or affect the condition, use or occupancy of the Property, including, without limitation, structural, utility system and life safety system changes necessitated by Developer’s acts, use of the Property or by improvements made by or for Developer.

 

10.5        No Waiver. The waiver by CRA or Developer of any agreement, condition or provision herein contained shall not be deemed to be a waiver of any subsequent breach of the same or any other agreement, condition or provision herein contained, nor shall any custom or practice which may grow up between the Parties in the administration of the terms hereof be construed to waive or to lessen the right of CRA or Developer to insist upon the performance by Developer in strict accordance with such terms.

 

10.6        Amendments. This Agreement may not be amended or modified in any respect whatsoever except by an instrument in writing signed by CRA and Developer.

 

10.7        Non Discrimination. Developer specifically covenants and agrees that Developer shall not discriminate against or segregate any person or group of persons on account of race, sex, creed, color, national origin, ancestry, religion, disability, marital status, familial status, age, sexual orientation, gender identity or expression in the occupancy, use, lease, tenure or enjoyment of the Property or any activity carried out by the performance of this Agreement.

 

10.8        Force Majeure. Either Party hereto shall be excused from performing any of its respective obligations or undertakings provided in this Agreement, excepting any of its respective obligations or undertakings to pay any sums of money under the applicable provisions hereof, for so long as the performance of such obligations are prevented or delayed, retarded or hindered (plus such additional time that is mutually consented to by the Parties) by act of God, weather of unusual severity, fire, earthquake, flood, hurricane, explosion, action of the elements, war (declared or undeclared), invasion, insurrection, riot, mob violence, sabotage, malicious mischief, inability to produce or general shortage of labor, equipment, facilities, materials or supplies in the open market, failure of transportation, strikes, lockouts, action of labor unions, condemnation, public requisition, laws, order of government or any other cause, whether similar or dissimilar to the foregoing, not within the reasonable control of the respective Party if such Party hereto gives notice of such delay to the other Party within twenty (20) days of the occurrence of such event.

 

10.9        Access and Review of Developer’s Books and Records. Developer shall at all times keep and maintain at a location within the City, accurate and complete records pertaining to the Improvements including, without limitation, such matters required to demonstrate Developer’s compliance with its obligations under this Agreement. The CRA and its representatives shall have, during normal business hours and upon reasonable advance notice, access to inspect, review and photocopy any and all such books and records of Developer relating to the Improvements.

 

  

25

  

 

10.10      Notices. All notices and elections (collectively, “Notices”) required or permitted to be given or delivered by or to any Party hereunder, shall be in writing and shall be (as elected by the Party giving such notice) hand delivered by messenger, courier service or prepaid overnight delivery service, by electronic transmission producing a written record, or alternatively shall be sent by United States Certified Mail, with Return Receipt Requested. The effective date of any Notice shall be the date of delivery of the Notice if by personal delivery, courier services or prepaid overnight delivery service, or if mailed, upon the date which the return receipt is signed or delivery is refused or the Notice designated by the postal authorities as non-deliverable, as the case may be. The Parties hereby designate the following addresses as the address to which Notices may be delivered, and delivery to such address shall constitute binding notice give to such Party:

 

If to CRA:

 

West Palm Beach Community Redevelopment Agency 

P.O. Box 3366

West Palm Beach, Florida 33402 

Attn: Executive Director

 

With a Copy to:

 

City of West Palm Beach 

Post Office Box 3366 

West Palm Beach, Florida 33402 

Attn: City Attorney

 

If to Developer:

 

Digital Domain Holdings Corporation 

10521 SW Village Center Drive, Suite 201

Port St. Lucie, FL 34987 

Attn: John Textor, CEO

 

10.11      Governmental Investigations. Developer shall cooperate fully and faithfully with any investigation, audit or inquiry conducted by any governmental authority that is empowered directly or by designation to compel the attendance of witnesses and to examine witnesses under oath, or conducted by a governmental authority that is a party in interest to the transaction, contract, Agreement, permit or license that is the subject of the investigation, audit or inquiry. In addition, Developer shall promptly report to the City Attorney any solicitation, of which Developer’s officers or directors have knowledge, of goods, money, requests for future employment or other benefit or thing of value by or on behalf of any employee of the CRA, the City or other person relating to the obtaining of this Agreement by Developer or affecting the performance of this Agreement.

 

  

26

  

 

10.12      Time is of the Essence. Time is of the essence with respect to the performance of every provision of this Agreement in which time of performance is a factor.

 

10.13      Successors and Assigns. All rights and obligations granted or imposed by this Agreement, and each and every provision hereof, except as herein otherwise specifically provided, shall extend to, bind and inure to the benefit of the Parties hereto and their respective successors and permitted assigns.

 

10.14      Governing Law and Venue. This Agreement shall be construed and interpreted, and the rights of the parties hereto determined, in accordance with Florida law. CRA and Developer submit to the jurisdiction of Florida courts and federal courts located in Florida. The Parties agree that proper venue for any suit concerning this Agreement shall be Palm Beach County, Florida, or the Federal Southern District of Florida. CRA and Developer each agree to waive all defenses to any suit filed in Florida based upon improper venue or forum nonconveniens.

 

10.15      Waiver of Jury Trial. CRA and Developer each waive the right to a trial by jury in any action or proceeding based upon, or related to, the subject matter of this Agreement. This waiver is knowingly, intentionally, and voluntarily made by each Party and each Party expressly acknowledges that neither the other Party nor any person acting on behalf of the other Party has made any representations of fact to include this waiver of trial by jury or in any way to modify or nullify its effect. Each Party acknowledges to the other that it has read and understands the meaning and effect of this waiver provision.

 

10.16      Integrated Agreement. This Agreement and the Exhibits attached hereto and forming a part hereof, constitute all covenants, promises, agreements, representations, conditions and understandings between the CRA and Developer concerning the Property, and there are no covenants, promises, representations, conditions or understandings by either Party or the agent of either Party hereto, either oral or written, between the Parties or relied upon by the Parties, other than are herein set forth. No subsequent alteration, modification, deletion, change or addition to this Agreement shall be binding upon the CRA or Developer unless same shall be in writing and signed by CRA and Developer.

 

10.17      No Third Party Beneficiaries. Nothing contained in this Agreement shall be construed so as to confer upon any other Party the rights of a third party beneficiary.

 

10.18      Americans With Disabilities Act. Notwithstanding anything to the contrary contained herein, Developer, at its sole cost and expense, shall (i) cause all alterations, additions, improvements and repairs to the Property to comply with the provisions of the Americans with Disabilities Act (“ADA”) and other similar federal, state, and local laws and regulations, including, without limitation, any alterations required under ADA for the purposes of “public accommodations” (as that term is used in the ADA).

 

  

27

  

 

10.19      No Partnership Relationship. It is understood and agreed that CRA shall in no event be construed or held to be a partner or associate of Developer in the conduct of Developer’s business, nor shall CRA be liable for any debts incurred by Developer in the conduct of Developer’s business, but it is understood and agreed that the relationship is and at all times shall remain that of CRA and Developer.

 

10.20      Interpretation. Each of the Parties hereto acknowledges that they have been represented by their own counsel throughout the negotiations and drafting of this Agreement and therefore neither of the Parties hereto shall claim or assert that any provisions of this Agreement should be construed against the drafter of this Agreement.

 

10.21      Severability. In the event that any term or provision hereunder (or the application thereof to any person or circumstances) shall to any extent be held invalid or unenforceable, it is agreed that the remainder of this Agreement (or the application of such terms or provision to persons or circumstances other than those as to which it is held invalid or unenforceable), shall not be affected and every other term and provision of this Agreement shall be deemed valid and enforceable to the maximum extent permitted by law.

 

10.22      Remedies Cumulative. Each right and remedy of either Party provided for in this Agreement, except as expressly provided otherwise, shall be cumulative and shall be in addition to every right other right or remedy provided for in this Agreement, or now or hereafter existing at law or in equity or by statute or otherwise, and the exercise or beginning of the exercise by a Party of any one or more of the rights or remedies provided for in this Agreement, or now or hereafter existing at law or in equity or by statute or otherwise, shall not preclude the simultaneous or later exercise by such Party of any or all other rights or remedies provided for in this Agreement or now or hereafter existing at law or in equity or by statute or otherwise.

 

10.23      Counterparts. This Agreement may be executed in one or more counterparts, each of which shall be deemed to be an original but all of which shall constitute one and the same agreement.

 

10.24      Nonliability of Officials and Employees. No member, official or employee of CRA, the City or any other governing body (including, without limitation, the Chair, Mayor or the Commissioners) shall be personally liable to Developer, or any successor in interest, in the event of any default or breach by CRA of for any amount or obligation which may become due to Developer or successor under the terms of this Agreement; and any and all such personal liability, either at common law or in equity or by constitution or statute, of, and any and all such rights and claims against, every such person, or under or by reason of the obligations, covenants or agreements contained in this Agreement, or implied therefrom are expressly waived and released as a condition or, and as a consideration for, the execution of this Agreement.

 

  

28

  

 

10.25      Performance of Government Functions. Notwithstanding anything in this Agreement to the contrary, nothing contained in this Agreement shall in any way stop, limit or impair the City from exercising or performing any regulatory, policing, legislative, governmental or other powers or functions with respect to the Property or the Improvements including, by way of illustration but not limitation, inspection of the Improvements in the performance of such functions. Nor shall anything in this Agreement constitute or imply approval or special handling and/or consideration for or exemption from any permit by the planning, zoning, building or other regulatory authorities of the City. Developer shall be required to comply with all procedures and requirements applicable to the Project that would also be applicable to any similarly situated development projects in the City.

 

10.26 Radon Gas. RADON GAS IS A NATURALLY OCCURRING RADIOACTIVE GAS THAT, WHEN IT HAS ACCUMULATED IN A BUILDING IN SUFFICIENT QUANTITIES, MAY PRESENT HEALTH RISKS TO PERSONS WHO ARE EXPOSED TO IT OVER TIME. LEVELS OF RADON THAT EXCEED FEDERAL AND STATE GUIDELINES HAVE BEEN FOUND IN BUILDINGS IN FLORIDA. ADDITIONAL INFORMATION REGARDING RADON AND RADON TESTING MAY BE OBTAINED FROM YOUR COUNTY PUBLIC HEALTH UNIT. SELLER REPRESENTS THAT IT HAS RECEIVED NO NOTICE AND IS NOT OTHERWISE AWARE OF THE PRESENCE OF RADON GAS AT THE PROPERTY IN EXCESS OF APPLICABLE GOVERNMENTAL LIMITATIONS.

 

(signatures appear on following page)

 

  

29

  

 

IN WITNESS WHEREOF, CRA and Developer have caused this Development Agreement to be executed the day and year first above aforesaid.

 

	
Signed, sealed and delivered 

in the presence of:

	 	
WEST PALM BEACH COMMUNITY 

REDEVELOPMENT AGENCY

	 	 	 	 
	/s/ Suzanne Payson	 	By: 	/s/ Lois J. Frankel
	Print Name: 	
Suzanne Payson

	 	 	
Lois J. Frankel, Chair

	 	 	 	 	 
	 	  	 	Date: 	
11/1/2010

	 	 	 	 
	/s/ Randy M Sherman	 	Attest: 	
Lisa Hedge

	Print Name: 	
Randy M Sherman

	 	 	
Deputy Secretary

	 	 	 	 	 
	 	  	 	 	
Office of CRA Counsel 

Approved as to form 

And legal sufficiency

	 	 	 	 	By:	SVP	  
	 	  	 	 	Date:	12/1/10	
  

	 	 	 	 	 
	 	  	 	
DIGITAL DOMAIN HOLDINGS 

CORPORATION

	 	 	 	 
	/s/ Jonathan Teaford	 	By: 	/s/ John Textor
	Print Name: 	
Jonathan Teaford

	 	 	
John Textor, CEO

	 	 	 	 	 
	 	  	 	Date: 	
11-1-10

	/s/ Ed Winsford	 	 	  
	Print Name:  	
Ed Winsford

	 	
Attest:

	
 

	 	 	 	
Secretary

	/s/ Christina Dixon 	 	 	  
	Print Name: 	Christina Dixon 	 	 	 

 

  

30

  

   

	
STATE OF FLORIDA

	
)

	
COUNTY OF PALM BEACH

	
)ss   

 

The foregoing instrument was acknowledged before me this 1day of November, 2010, by Lois J. Frankel, and  Lisa Hedge, as Chair and Secretary, respectively, of the West Palm Beach Community Redevelopment Agency, who are personally known to me.

  

	  	Lindsay L. Schaefer  
	
(NOTARY SEAL)

	
NOTARY PUBLIC

	  	  
	  	  
	  	
Printed name of notary

	 	

 

	
STATE OF FLORIDA

	
)

	
COUNTY OF ST. LUCIE

	
)ss

 

The foregoing instrument was acknowledged before me this 29 day of October, 2010, by John Textor, CEO of Digital Domain Holdings Corporation, who is personally known to me to be the person who subscribed to the foregoing instrument, and acknowledged that he executed the same on behalf of said corporation and that he was duly authorized so to do.

 

	 	Lindsay Henry
	
(NOTARY SEAL)

	
NOTARY PUBLIC

	  	  
	  	/s/ Lindsay Henry 
	  	
Printed name of notary

		 

 

  

31

  

 

EXHIBIT A

 

THE PROPERTY

 

LOT(S) 2, 3, 4, 5, 6, 7, 8, 13, 14, 15, 16, 17, 18, 19 AND 20, BLOCK 58, TOGETHER WITH THE 14 FOOT ALLEY ADJACENT TO SAID LOTS AS SHOWN ON THE ASUBDIVISION OF BLOCK 58 MODEL LAND CO. ADDITION TO WEST PALM BEACH, FLORIDA,@ ACCORDING TO THE PLAT THEREOF ON FILE IN THE OFFICE OF THE CLERK OF THE CIRCUIT COURT IN AND FOR PALM BEACH COUNTY, FLORIDA, RECORDED IN PLAT BOOK 2, PAGE 65. SAID LANDS SITUATE, LYING AND BEING IN PALM BEACH COUNTY, FLORIDA LESS THAT PORTION OF SAID LOTS 2, 4, 5, 6, 7 AND 8, TAKEN FOR OKEECHOBEE BOULEVARD RIGHT-OF-WAY AS PER INSTRUMENT RECORDED IN OFFICIAL RECORD BOOK 7115, PAGE 457, OF THE SAID PUBLIC RECORDS, LESS THE EAST 12.00 FEET OF SAID LOTS 2, 3, 18 AND 19, AS PER INSTRUMENT(S) RECORDED IN DEED BOOK 399, PAGE 371 AND IN DEED BOOK 401, PAGE 3, OF SAID PUBLIC RECORDS AND LESS THE EAST 10.00 FEET OF LOT 20.

 

  

32

  

 

EXHIBIT B

 

DEED

 

Prepared by, record and return to: 

 

Suzanne Payson, Esquire 

West Palm Beach Community 

Redevelopment Agency 

401 Clematis Street, 5th Floor 

West Palm Beach, Florida 33401

 

PCN#

 

SPECIAL WARRANTY DEED 

AND RESTRICTIVE COVENANT

 

This Special Warranty Deed is made this                          day of                  ,20       ,  by and between the West Palm Beach Community Redevelopment Agency, a body corporate and politic organized pursuant to Chapter 163, Florida Statutes, having an address at 401Clematis Street, West Palm Beach, FL 33401 (“Grantor”), and                                                      , a                                                               , having an address at                                                                              (“Grantee”).

 

WITNESSETH:

 

Grantor, in consideration of Ten and 00/100 ($10.00) Dollars, and other good and valuable consideration, to it paid by Grantee, the receipt whereof is hereby acknowledged, hereby grants, sells and conveys to Grantee, its successors and assigns forever all of that certain land situated and located in Palm Beach County, Florida and more particularly described as follows (the “Property”):

 

LOT(S) 2, 3, 4, 5, 6, 7, 8, 13, 14, 15, 16, 17, 18, 19 AND 20, BLOCK 58, TOGETHER WITH THE 14 FOOT ALLEY ADJACENT TO SAID LOTS AS SHOWN ON THE ASUBDIVISION OF BLOCK 58 MODEL LAND CO. ADDITION TO WEST PALM BEACH, FLORIDA,@ ACCORDING TO THE PLAT THEREOF ON FILE IN THE OFFICE OF THE CLERK OF THE CIRCUIT COURT IN AND FOR PALM BEACH COUNTY, FLORIDA, RECORDED IN PLAT BOOK 2, PAGE 65. SAID LANDS SITUATE, LYING AND BEING IN PALM BEACH COUNTY, FLORIDA LESS THAT PORTION OF SAID LOTS 2, 4, 5, 6, 7 AND 8, TAKEN FOR OKEECHOBEE BOULEVARD RIGHT-OF-WAY AS PER INSTRUMENT RECORDED IN OFFICIAL RECORD BOOK 7115, PAGE 457, OF THE SAID PUBLIC RECORDS, LESS THE EAST 12.00 FEET OF SAID LOTS 2, 3, 18 AND 19, AS PER INSTRUMENT(S) RECORDED IN DEED BOOK 399, PAGE 371 AND IN DEED BOOK 401, PAGE 3, OF SAID PUBLIC RECORDS AND LESS THE EAST 10.00 FEET OF LOT 20.

 

  

33

  

 

TOGETHER with all the tenements, hereditaments and appurtenances thereto belonging or in anywise appertaining.

 

SUBJECT TO:

 

	 	
1. 

	
Taxes and assessments for the year                             and subsequent years;

	
  

	
2.

	
Easements, reservations, agreements, and restrictions of record, if any, without hereby reimposing same;

	
  

	
3.

	
Zoning ordinances and all other restrictions and regulations imposed by governmental authorities;

	 	
4. 

	
All matters that would be shown on a current, accurate survey; and

	 	
5. 

	
That certain Leasehold Estate retained by Grantor in the Property.

 

TO HAVE AND TO HOLD, in the same in fee simple forever.

 

AND the Grantor hereby covenants with said Grantee that it is lawfully seized of said lands in fee simple; that it has good right and lawful authority to sell and convey said land; that it hereby warrants the title to said land and will defend the same against the lawful claims of all persons claiming by, through or under the said Grantor.

 

Grantee shall use the Property in accordance with the terms and conditions of the Development Agreement dated                                                                          by and between Grantor and Grantee and recorded at                                                               , the terms of which are incorporated into this Deed by reference, which shall operate as a restrictive covenant on the Property.

 

In the event that (a) Grantee does not satisfy the Post Closing Obligations set forth in the Development Agreement by December 31, 2012 (as may be extended in accordance with the Development Agreement), or (b) commence Vertical Construction of the Phase I Improvements, as defined in the Development Agreement by December 31, 2013 (as such date may be extended in accordance with the Development Agreement), then, all right, title and interest in and to the Property shall automatically revert to the Grantor.

 

The Grantor hereby binds itself and its successors to warrant the title as against all acts of the Grantor herein and no other, subject only to the matters set forth above.

 

  

34

  

 

In Witness Whereof, Grantor has caused this instrument to be signed by its duly authorized officer on the date first above written.

 

	  	 	
WEST PALM BEACH COMMUNITY 

REDEVELOPMENT AGENCY

	 	 	 	 
	 	 	
By:

	 
	
Signature

	 	 	
                                                                              , Chair

	 	 	 	 
	 	 	 	 
	
Print Name

	 	 	  
	  	 	
ATTEST:

	
 

	  	 	 	
Secretary

	
Signature

	 	 	  
	 	 	 	 
	 	 	 	 
	
Print Name

	 	 	  
	  	 	 	
CRA Counsel

	  	 	 	
Approved as to form

	  	 	 	
And legal sufficiency

	  	 	 	By:	 	
    

	  	 	 	Date:	 	
  

  

	
STATE OF FLORIDA

	
)

	
COUNTY OF PALM BEACH

	
)ss   

 

The foregoing instrument was acknowledged before me this                  day of                               , 20                               , by                               , and                                ______, as Chair and Secretary, respectively, of the West Palm Beach Community Redevelopment Agency, who are personally known to me.

 

	
(NOTARY SEAL)

	  
	  	  
	  	
 

	  	
NOTARY PUBLIC

	  	  
	  	
 

	  	
Printed name of notary

 

  

35

  

 

EXHIBIT C 

 

ALLEY

 

  

36

  

 

EXHIBIT D 

 

LEGAL DESCRIPTION – PHASE I PARCEL

 

(to be attached upon approval of the Level III Site Plan for Phase I)

 

  

37

  

 

EXHIBIT E

 

UNCONDITIONAL GUARANTY 

OF REPAYMENT

 

THIS UNCONDITIONAL GUARANTY OF REPAYMENT (this “Guaranty” or this “Agreement”) is made as of                          by John C. Textor, an individual (“Guarantor”), having a business address at 10521 SW Village Center Drive, Suite 201, Port St. Lucie, FL 34987.

 

RECITALS:

 

A.           The West Palm Beach Community Redevelopment Agency, having an address at P.O. Box 3366, West Palm Beach, Florida 33402 (“Lender”), has agreed to make available to Digital Domain Holdings Corporation, a Florida corporation, having an address at 10521 SW Village Center Drive, Suite 201 Port St. Lucie, FL 34987 (“Borrower”), a term loan in the amount of Fifteen Million United States Dollars (U.S.$ 15,000,000.00) (the “Loan”).

 

B.           Borrower and Lender have executed a Loan Agreement of even date herewith (the “Loan Agreement”) which sets forth certain of the terms of the Loan.

 

C.           In order to evidence the Loan, Borrower has executed and delivered to Lender a Promissory Note of even date herewith in the principal amount of Fifteen Million United States Dollars (U.S.$ 15,000,000.00) (the “Note”). Repayment of the Note is secured by various security instruments. The Note, the Loan Agreement, and the other instruments and documents delivered in connection therewith are hereinafter collectively referred to as the “Loan Documents”.

 

D.           Lender has agreed to make the Loan to Borrower in consideration, among other things, of the covenants and obligations made and assumed by Guarantor as herein set forth.

 

E.           Guarantor will benefit directly from the making of the Loan to Borrower.

 

NOW, THEREFORE, for good and valuable consideration, intending to be legally bound hereby, Guarantor irrevocably and unconditionally agrees as follows:

 

1.           Guarantor hereby unconditionally guarantees to Lender the punctual repayment of all sums due pursuant to the terms of the Note and the other Loan Documents, and any subsequent amendments, extensions, renewals or consolidations thereof (the “Repayment Guaranty”).

 

2.           Guarantor hereby waives any right to notice of advances made to Borrower from time to time under the provisions of the Loan Documents, waives any rights Guarantor may have by reason of any forbearance, modification, waiver, or renewal or extension which Lender may grant, or to which Lender and Borrower may agree, with respect to the Loan Documents, waives notice of acceptance of this Guaranty, and waives presentment, demand, notice or protest of any kind, other than as expressly provided for hereunder.

 

  

38

  

 

3.           The obligations of Guarantor under this Agreement are primary, absolute, independent, irrevocable and unconditional. This shall be an agreement of suretyship as well as of guaranty, and Lender may proceed directly against Guarantor without being required to proceed first against Borrower or any other person or entity, or against any other security for Borrower’s obligations to Lender.

 

4.           The obligations of Guarantor under this Agreement shall be unconditional and irrevocable, irrespective of either (a) the genuineness, validity or enforceability, of the Loan Documents, (b) the existence of any security given to secure the Note, (c) impossibility or the illegality of performance on the part of Borrower of its obligations under the Loan Documents, (d) any defense that may arise by reason of the incapacity or lack of authority of Borrower or Guarantor or the failure of Lender to file or enforce a claim against the estate of Borrower or Guarantor in any bankruptcy or other proceeding, or (e) any other circumstances, occurrence or condition, whether similar or dissimilar to any of the foregoing, which might otherwise constitute a legal or equitable defense, discharge or release of a guarantor or surety.

 

5.           Guarantor agrees that Lender may at any time and from time to time, with or without consideration, either release any one or more guarantors of the Note or other Loan Documents and/or release Borrower from its obligations under the Note or other Loan Documents. Any such action shall not in any way affect or diminish the liability of Guarantor under this Agreement. If Guarantor pays all sums due and owing under the Loan Documents, then Guarantor shall be subrogated to the rights of Lender under the Loan Documents and Lender shall, upon the request of Guarantor, assign the Loan Documents to Guarantor without representation or warranty of any kind.

 

6.           If Guarantor shall advance any sums to Borrower or its successors or assigns, or if the Borrower or its successors or assigns shall now be or hereafter become indebted to Guarantor, such sums or indebtedness shall be subordinate in payment and in all other respects to the amounts then or thereafter due and owing to Lender under the Loan Documents. If Guarantor collects any of such sums or indebtedness from Borrower at any time when Borrower is in default under the Loan Documents or when any accrued installment of principal, interest, or additional interest is unpaid under the Note or when it is reasonably foreseeable that the payment of such sums to Guarantor will render Borrower financially unable to duly perform any of Borrower’s subsequent obligations under the Loan Documents, such collected funds shall be deemed collected and received by Guarantor in trust for Lender, and shall be paid over to Lender, upon demand by Lender, for application, when received, on account of Borrower’s obligations under the Loan Documents. Nothing herein contained shall be construed to give Guarantor any right of subrogation in and to the Loan Documents or all or any part of the Lender’s interest in the Loan Documents, until all amounts owing to Lender thereunder have been paid in full.

 

  

39

  

 

7.           Guarantor represents and warrants that (a) Guarantor has either examined the Loan Documents or has had an opportunity to examine the Loan Documents and has waived the right to examine them; (b) Guarantor has the full power, authority and legal right to enter into, execute and deliver this Agreement; (c) this Agreement is a valid and a binding legal obligation of Guarantor, and is fully enforceable against Guarantor in accordance with its terms; (d) the execution, delivery and performance by Guarantor of this Agreement will not violate or constitute a default under any indenture, note, loan or credit agreement or any other agreement or instrument to which Guarantor is a party or is bound; and (e) Guarantor has a direct financial interest in Borrower and will derive direct, substantial benefit from the Loan to Borrower.

 

8.           Notwithstanding anything contained in this Agreement or in the Loan Documents to the contrary, Guarantor shall be in default under this Agreement upon the making by Guarantor of an assignment for the benefit of creditors, or the appointment of a trustee or receiver for Guarantor, or for any property of Guarantor, or the commencement of any proceeding by or (if not dismissed or stayed within one hundred twenty (120) days after such commencement) against Guarantor, under any bankruptcy, reorganization, arrangement, insolvency, readjustment, receivership or similar law, or if any representation or warranty made by Guarantor in this Agreement is incorrect or fails to state a material fact which is necessary to make the representation or warranty not misleading in the light of the circumstances in which it was made, or if Guarantor fails to perform in any material respect any of his obligations under this Agreement or breaches in any material respect any of his covenants under this Agreement. Upon the occurrence of any such default, Lender may, at its option, as to Guarantor, accelerate the indebtedness evidenced and secured by the Loan Documents.

 

9.           All notices and other communications required under this Guaranty shall be in writing and shall be deemed to have been properly given, if personally delivered, on the date of such delivery, or, if sent by Certified or Registered U.S. Mail, return receipt requested, on the third (3rd) business day following deposit in the U.S. Mail, postage prepaid, or if sent by overnight courier with guaranteed overnight delivery, on the day following the date delivered to such overnight courier. All notices shall be addressed to the party to whom it is intended at its address set forth on the first page of this Guaranty. Any party may designate a change of address by written notice to the other, given at least ten (10) business days before such change of address is to become effective.

 

10.           All rights and remedies of Lender under this Agreement, the Loan Documents, or by law are separate and cumulative, and the exercise of one shall not limit or prejudice the exercise of any other such rights or remedies. The enumeration in this Agreement of any waivers or consents by Guarantor shall not be deemed exclusive of any additional waivers or consents by Guarantor which may be deemed to exist, in law or equity. No delay or omission by Lender in exercising any such right or remedy shall operate as a waiver thereof. No waiver of any rights and remedies hereunder, and no modification or amendment of this Agreement, shall be deemed made by Lender unless in writing and duly signed by Lender. Any such written waiver shall apply only to the particular instance specified therein and shall not impair the further exercise of such right or remedy or of any other right or remedy of Lender, and no single or partial exercise of any right or remedy under this Agreement shall preclude any other or further exercise thereof or any other right or remedy.

 

  

40

  

 

11.           If Lender employs counsel to enforce this Agreement by suit or otherwise, Guarantor will reimburse Lender, upon demand, for all reasonable expenses incurred in connection therewith (including, without limitation, reasonable attorneys’ fees incurred at trial, on appeal or in connection with any bankruptcy proceedings) whether or not suit is actually instituted.

 

12.           In addition to all liens upon and right of setoff against monies, securities, or other property of Guarantor given to Lender by law or equity, Lender and its affiliates shall have a lien upon and right of set off against all monies, securities and other property of Guarantor now or hereafter in the possession of or on deposit with Lender or any affiliate, whether held in a general or special account for deposit, or for safekeeping or otherwise. Every such lien and right of setoff may be exercised after the occurrence of a default by Guarantor under this Agreement without notice to Guarantor.

 

13.           This Agreement shall be binding upon Guarantor, and Guarantor’s heirs, administrators, executors, successors and assigns, and shall inure to the benefit of Lender (and its affiliates as appropriate) and its successors and assigns.

 

14.           Nothing contained in this Agreement is intended to supersede, modify or otherwise affect any other guaranty or suretyship agreement from Guarantor to Lender.

 

15.           The obligations and liabilities of Guarantor hereunder shall be joint and several with the obligations and liabilities of Borrower and any other guarantors of the Loan and Lender may proceed against all or some or any of them in any order. For purposes of this instrument the singular shall be deemed to include the plural, and the neuter shall be deemed to include the masculine and feminine, as the context may require.

 

16.           If any provision of this Agreement is held to be invalid or unenforceable by a court of competent jurisdiction, the other provisions of this Agreement shall remain in full force and effect and shall be liberally construed in favor of Lender in order to effect the provisions of this Agreement.

 

17.           Guarantor agrees that this Agreement shall be governed by and construed according to the laws of the State of Florida regardless of where the residence or domicile of Guarantor is now or may hereafter be located.

 

18.           GUARANTOR AND LENDER HEREBY WAIVE ANY AND ALL RIGHTS TO A TRIAL BY JURY IN ANY ACTION, PROCEEDING, COUNTERCLAIM OR SUBSEQUENT PROCEEDING BROUGHT BY LENDER, BORROWER OR ANY GUARANTOR OF ANY OBLIGATION CREATED UNDER THIS AGREEMENT, THE NOTE OR ANY OF THE OTHER LOAN DOCUMENTS AGAINST ANY OR ALL OF THE OTHERS ON ANY MATTERS WHATSOEVER ARISING OUT OF, OR IN ANY WAY RELATED TO, THIS AGREEMENT, THE NOTE OR ANY OF THE OTHER LOAN DOCUMENTS.

 

  

41

  

 

IN WITNESS WHEREOF, Guarantor has executed this Agreement the day and year first above written.

 

	
     

	     	
/s/ John C. Textor

	  
	  	  	John C. Textor  	  

 

  

42

  

 

EXHIBIT F

 

LEGAL DESCRIPTION – PHASE II PARCEL

     

(to be attached upon approval of the Level III Site Plan for Phase I)

 

  

43

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00191-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00191-of-00352.parquet"}]]