Document:

<PAGE>

                                                                   EXHIBIT 10.24

                    AIA Document B141/CMa - Electronic Format

                       Standard Form of Agreement Between
                               Owner and Architect

               Where the Construction Manager is NOT a Constructor

                   1992 CONSTRUCTION MANAGER - ADVISER EDITION

THIS DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES; CONSULTATION WITH AN ATTORNEY IS
ENCOURAGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION. AUTHENTICATION OF
THIS ELECTRONICALLY DRAFTED AIA DOCUMENT MAY BE MADE BY USING AIA DOCUMENT D401.

This document is intended to be used in conjunction with the 1992 editions of
AIA Documents B801/CMa, A101/CMa and A201/CMa.

Copyright 1975,1980, (C) 1992 by The American Institute of Architects, 1735 New
York Avenue, N. W. Washington, D.C. 20006-5292. Reproduction of the material
herein or substantial quotation of its provisions without the written permission
of the AIA violates the copyright laws of the United States and will subject the
violator to legal prosecution.

AGREEMENT
made as of the 15th day of January in the year of 2003
(In words, indicate day, month and year.)

BETWEEN the Owner:
(Name and address)
Advanced Neuromodulation Systems
6501 Windcrest, Suite 100
Plano, TX 75024
ATTN: MR. MYRON ALBERT

and the Architect:
(Name and address)
Good Fulton & Farrell Architects
2808 Fairmount, Suite 300
Dallas, TX 75201
ATTN: JOSEPH J. PATTI

for the following Project:
(Include detailed description of Project, location, address and scope.)

A two-story building of approximately 143,500 S.F. as defined in the Project
Definition Requirements - Final Report dated 12.26.02, and incorporated herein
by reference, located on Lot 2 EDS Lakes Addition Block B, a 15.413-acre (10.00
acre net) tract, Plano, Texas.

The Construction Manager is:
(Name and address)
Koll Development Company
8411 Preston Rd., Suite 700
Dallas, Texas 75225
ATTN: MIKE ROSAMOND

The Owner and Architect agree as set forth below.

          TERMS AND CONDITIONS OF AGREEMENT BETWEEN OWNER AND ARCHITECT

                                    ARTICLE 1
                          ARCHITECT'S RESPONSIBILITIES

1.1      ARCHITECT'S SERVICES

(C) 1992 - THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE N.W.
WASHINGTON, D.C. 200016-5292. AIA DOCUMENT B141/CMa - OWNER-ARCHITECT AGREEMENT
- CONSTRUCTION MANAGER-ADVISER EDITION - 1992 EDITION - AIA(R) - WARNING:
Unlicensed photocopying violates U.S. copyright laws and will subject the
violator to legal prosecution. This document was electronically produced with
permission of the AIA and can be reproduced in accordance with your license
without violation until the date of expiration as noted below, expiration as
noted below, expiration as noted below, expiration as noted below, expiration as
noted below. User Document: ans b141cma v3.aia -- 6/16/2003. AIA License Number
1013444, which expires on 1/31/2004.

                                                 Electronic Format B141/CMa-1992

                                                                               1
<PAGE>

1.1.1    The Architect's services consist of those services performed by the
Architect, Architect's employees and Architect's consultants as enumerated in
Articles 2 and 3 of this Agreement and any other services included in Article
12.

1.1.2    The Architect's services shall be provided in conjunction with the
services of a Construction Manager as described in the edition of AIA Document
B801/CMa, Standard Form of Agreement Between Owner and Construction Manager,
current as of the date of this Agreement. Architect agrees that it will
cooperate and consult with the Construction Manager, and will incorporate any
value engineering proposals where directed in writing by the Construction
Manager and approved by the Owner, and will incorporate such proposals in
accordance with the provisions of this Agreement.

1.1.3    The Architect's services shall be performed as expeditiously as is
consistent with professional skill and care and the orderly progress of the
Work. The Architect shall submit for the Owner's approval and the Construction
Manager's information a schedule for the performance of the Architect's services
which may be adjusted as the Project proceeds, and shall include allowances for
periods of time required for the Owner's and Construction Manager's review and
for approval of submissions by authorities having jurisdiction over the Project.
Time limits established by this schedule approved by the Owner shall not, except
for reasonable cause, be exceeded by the Architect or Owner.

1.1.4    The services covered by this Agreement are subject to the time
limitations contained in Subparagraph 11.5.1.

                                    ARTICLE 2
                       SCOPE OF ARCHITECT'S BASIC SERVICES

2.1      DEFINITION

2.1.1    The Architect's Basic Services consist of those described in 2.2
through 2.6 and any other services identified in Article 12 as part of Basic
Services, and include normal structural, civil, landscape architecture,
mechanical and electrical engineering services.

2.2      SCHEMATIC DESIGN PHASE

2.2.1    The Architect shall prepare the program and review the schedule and
construction budget furnished by the Owner to ascertain the requirements of the
Project and shall arrive at a mutual understanding of such requirements with the
Owner.

2.2.2    The Architect shall review with the Owner and Construction Manager
proposed site use and improvements; selection of materials, building systems and
equipment; and methods of Project delivery.

2.2.3    The Architect shall review with the Owner and Construction Manager
alternative approaches to design and construction of the Project.

2.2.4    Based on the mutually approved program, schedule and construction
budget requirements, the Architect shall prepare, for approval by the Owner,
Schematic Design Documents consisting of drawings and other documents
illustrating the scale and relationship of Project components.

2.2.5    At intervals appropriate to the progress of the Schematic Design Phase
and mutually agreeable to the Owner, Construction Manager and Architect, the
Architect shall provide schematic design studies for the Owner's review and the
Construction Manager's information.

2.2.6    In the further development of the drawings and specifications during
this and subsequent phases of design, the Architect shall be entitled to assume
the accuracy of the estimates of Construction Cost which are to be provided by
the Construction Manager under the Construction Manager's agreement with the
Owner.

2.2.7    Upon completion of the Schematic Design Phase, the Architect shall
provide drawings, outline specifications and other documents for the Owner's
approval and the Construction Manager's information.

2.3      DESIGN DEVELOPMENT PHASE

2.3.1    Based on the approved Schematic Design Documents and any adjustments
authorized by the Owner in the program, schedule or construction budget, the
Architect shall prepare Design Development Documents for the Construction
Manager's review and the Owner's approval. The Design Development Documents
shall be based upon data and estimates prepared by the Construction Manager and
shall consist of drawings and other documents that establish and describe the
size and character of the Project as to architectural, structural, mechanical
and electrical systems, materials and such other elements as may be appropriate.

2.3.2    At intervals mutually agreeable to the Owner, Construction Manager and
Architect, the Architect shall provide drawings and other documents which depict
the current status of design development for the Owner's review and the
Construction Manager's information.

2.3.3    Upon completion of the Design Development Phase, the Architect shall
provide drawings, outline specifications and other documents for the Owner's
approval and the Construction Manager's information.

2.4      CONSTRUCTION DOCUMENTS PHASE

2.4.1    Based on the approved Design Development Documents and any further
adjustments authorized by the Owner in the scope or quality of the Project or in
the construction budget, the Architect, utilizing data and estimates prepared by
the Construction Manager, shall prepare, for approval by the Owner, Construction
Documents consisting of Drawings and Specifications setting forth in detail the

AIA DOCUMENT B141/CMa - OWNER-ARCHITECT AGREEMENT - CONSTRUCTION MANAGER-ADVISER
EDITION - 1992 EDITION - AIA(R) - (C) 1992 - THE AMERICAN INSTITUTE OF
ARCHITECTS, 1735 NEW YORK AVENUE N.W., WASHINGTON, D.C. 20006-5292. WARNING:
Unlicensed photocopying violates U.S. copyright laws and will subject the
violator to legal prosecution. This document was electronically produced with
permission of the AIA and can be reproduced in accordance with your license
without violation until the date of expiration as noted below. User Document:
b141 01_15_03.aia -- 2/10/2003. AIA License Number 1009668, which expires on
3/28/2003.

                                                 Electronic Format B141/CMa-1992

                                                                               2
<PAGE>

requirements for the construction of the Project. The Architect will incorporate
value engineering items into the Construction Documents as directed in writing
by the Construction Manager and approved by Owner and will incorporate such
value engineering items in accordance with the provisions of this Agreement.

2.4.2    At intervals mutually agreeable to the Owner, Construction Manager and
Architect, the Architect shall provide Drawings and Specifications for the
Owner's and the Construction Manager's review.

2.4.3    Upon completion of the Construction Documents Phase, the Architect
shall provide Construction Documents for the Owner's approval and the
Construction Manager's information.

2.4.4    The Architect shall assist the Owner and Construction Manager in the
preparation of the necessary bidding information, bidding forms, the Conditions
of the Contracts, and the forms of Agreement between the Owner and the
Contractors. The Architect shall assist the Construction Manager in issuing
bidding documents to bidders and conducting prebid conferences with prospective
bidders. The Architect, with the assistance of the Construction Manager, shall
respond to questions from bidders, and shall issue addenda.

2.4.5    The Architect shall assist the Owner and Construction Manager in
connection with the Owner's responsibility for filing documents required for the
approval of governmental authorities having jurisdiction over the Project.

2.5      BIDDING OR NEGOTIATION PHASE

2.5.1    The Architect, following the Owner's approval of the Construction
Documents and of the Construction Manager's latest estimate of Construction
Cost, shall assist the Construction Manager in obtaining bids or negotiated
proposals and assist in preparing contracts for construction.

2.6      CONSTRUCTION PHASE-ADMINISTRATION OF THE CONSTRUCTION CONTRACT

2.6.1    The Architect's responsibility to provide Basic Services for the
Construction Phase under this Agreement commences with the award of the Contract
for construction and terminates 30 days after final completion of the Work.

2.6.2    The Architect shall provide administration of the Contract for
construction in cooperation with the Construction Manager as set forth below and
in the edition of AIA Document A20l/CMa, General Conditions of the Contract for
Construction, Construction Manager-Adviser Edition, as amended, current as of
the date of this Agreement.

Provided, however, with respect to the responsibilities and duties of the
Architect, the General Conditions shall be modified to be consistent with this
Agreement.

2.6.3    Duties, responsibilities and limitations of authority of the Architect
shall not be restricted, modified or extended without written agreement of the
Owner and Architect with consent of the Contractors and the Construction
Manager, which consent shall not be unreasonably withheld.

2.6.4    The Architect shall be a representative of and shall advise and consult
with the Owner (1) during construction until final payment to the Contractors is
due, and (2) as an Additional Service at the Owner's direction from time to time
during the correction period described in the Contracts for Construction. The
Architect shall have authority to act on behalf of the Owner only to the extent
provided in this Agreement unless otherwise modified by written instrument.

2.6.5    The Architect shall visit the site at regular intervals appropriate to
the stage of construction or as otherwise agreed by the Owner and Architect in
writing to become generally familiar with the progress and quality of the Work
completed and to determine in general if the Work is being performed in a manner
indicating that the Work when completed will be in accordance with the Contract
Documents. However, the Architect shall not be required to make exhaustive or
continuous on-site inspections to check the quality or quantity of the Work. On
the basis of on-site observations as an architect, the Architect shall keep the
Owner informed of the progress and quality of the Work, and defects and
deficiencies in the Work. The  Architect will exercise professional care and
customary  diligence in discovering and promptly reporting to the Construction
Manager and Owner any observable material defects or deficiencies in the Project
or the Work of the Contractors, any Subcontractors, or any sub-subcontractors,
their agents or employees, or any person performing any of the Work in the
construction of the Project. (More extensive site representation may be agreed
to as an Additional Service, as described in Paragraph 3.2.)

2.6.6    The Architect shall not have control over or charge of and shall not be
responsible for construction means, methods, techniques, sequences or
procedures, or for safety precautions and programs in connection with the Work,
since these are the Contractors' responsibility under the Contracts for
Construction. The Architect shall not be responsible for the Contractors'
schedules or failure to carry out the Work in accordance with the Contract
Documents. The Architect shall not be responsible for the performance by the
Construction Manager of the services required by the Construction Manager's
agreement with the Owner. The Architect shall not have control over or charge of
acts or omissions of the Contractors, Subcontractors, or their agents or
employees, or of any other persons performing services or portions of the Work,
but will promptly advise the Owner and Construction Manager of any material
wrongful or non conforming acts or omissions.

AIA DOCUMENT B141/CMa - OWNER-ARCHITECT AGREEMENT - CONSTRUCTION MANAGER-ADVISER
EDITION - 1992 EDITION - AIA(R) - (C) 1992 - THE AMERICAN INSTITUTE OF
ARCHITECTS, 1735 NEW YORK AVENUE N.W., WASHINGTON, D.C. 20006-5292. WARNING:
Unlicensed photocopying violates U.S. copyright laws and will subject the
violator to legal prosecution. This document was electronically produced with
permission of the AIA and can be reproduced in accordance with your license
without violation until the date of expiration as noted below. User Document:
b141 01_15_03.aia -- 2/10/2003, AIA License Number 1009668, which expires on
3/28/2003.

                                                 Electronic Format B141/CMa-1992

                                                                               3

<PAGE>

which the Architect discovers during the course of its duties under the
Contractor Documents.

2.6.7    The Architect shall at all times have access to the Work wherever it is
in preparation or progress.

2.6.8    Communications by and with the Architect's consultants shall be through
the Architect.

2.6.9    Based on the Architect's observations and evaluations of each
Contractor's Application for Payment, the Architect shall review and certify the
amounts due the respective Contractors.

2.6.9.1  The Architect's certification for payment shall constitute a
representation to the Owner, based on the Architect's observations at the site
as provided in Subparagraph 2.6.5, on the recommendations of the Construction
Manager and on the data comprising the Contractors' Applications for Payment,
that, to the best of the Architect's knowledge, information and belief, the Work
has progressed to the point indicated and the quality of the Work is in
accordance with the Contract Documents. The foregoing representations are
subject to an evaluation of the Work for conformance with the Contract Documents
upon Substantial Completion, to results of subsequent tests and inspections, to
minor deviations from the Contract Documents correctable prior to completion and
to specific qualifications expressed by the Architect. The issuance of a
Certificate for Payment shall further constitute a representation that the
Contractor is entitled to payment in the amount certified.

2.6.9.2  The issuance of a Certificate for Payment shall not be a representation
that the Architect has (1) made exhaustive or continuous on-site inspections to
check the quality or quantity of the Work, (2) reviewed construction means,
methods, techniques, sequences or procedures, (3) reviewed copies of
requisitions received from Subcontractors and material suppliers and other data
requested by the Owner to substantiate the Contractor's right to payment or (4)
ascertained how or for what purpose the Contractor has used money previously
paid on account of the Contract Sum.

2.6.10   The Architect shall have authority, after notification to the
Construction Manager, to reject Work which does not conform to the Contract
Documents. Whenever the Architect considers it necessary or advisable for
implementation of the intent of the Contract Documents, the Architect will have
authority, upon written authorization from the Owner, to require additional
inspection or testing of the Work in accordance with the provisions of the
Contract Documents, whether or not such Work is fabricated, installed or
completed. However, neither this authority of the Architect nor a decision made
in good faith either to exercise or not to exercise such authority shall give
rise to a duty or responsibility of the Architect to the Construction Manager,
Contractors, Subcontractors, material and equipment suppliers, their agents or
employees or other persons performing portions of the Work.

2.6.11   The Architect shall review and approve or take other appropriate action
upon Contractors' submittals such as Shop Drawings, Product Data and Samples,
but only for the limited purpose of checking for conformance with information
given and the design concept expressed in the Contract Documents. The
Architect's action shall be taken with such reasonable promptness as to cause no
delay in the Contractors' Work or in construction by the Owner's own forces,
while allowing sufficient time in the Architect's professional judgment to
permit adequate review. Review of such submittals is not conducted for the
purpose of determining the accuracy and completeness of other details such as
dimensions and quantities or for substantiating instructions for installation or
performance of equipment or systems designed by the Contractors, all of which
remain the responsibility of the Contractors to the extent required by the
Contract Documents. The Architect's review shall not constitute approval of
safety precautions or, unless otherwise specifically stated by the Architect, of
construction means, methods, techniques, sequences or procedures. The
Architect's approval of a specific item shall not indicate approval of an
assembly of which the item is a component. When professional certification of
performance characteristics of materials, systems or equipment is required by
the Contract Documents, the Architect shall be entitled to rely upon such
certification to establish that the materials, systems or equipment will meet
the performance criteria required by the Contract Documents.

2.6.12   The Architect shall review and sign or take other appropriate action on
Change Orders and Construction Change Directives prepared by the Construction
Manager for the Owner's approval and execution in accordance with the Contract
Documents.

2.6.13   The Architect may authorize minor changes in Work not involving an
adjustment in a Contract Sum or an extension of a Contract Time which are not
inconsistent with the intent of the Contract Documents. Such changes shall be
effected by written order issued through the Construction Manager.

2.6.14   The Architect, assisted by the Construction Manager, shall conduct
inspections to determine the date or dates of Substantial Completion and the
date of final completion. The Architect shall forward to the Owner warranties
and similar submittals required by the Contract Documents which have been
received from the Construction Manager. The Architect shall issue a final
Project Certificate for Payment upon compliance with the requirements of the
Contract Documents.

2.6.15   The Architect shall interpret and decide matters concerning performance
of the Owner and Contractor under the requirements of the Contract Documents on
written request of either the Owner or Contractor. The Architect's response to
such requests shall be made with reasonable promptness and within any time
limits agreed upon.

2.6.16   Interpretations and decisions of the Architect shall be consistent with
the intent of and reasonably inferable from the Contract Documents and shall be
in writing or in the form of drawings. When making such interpretations and
initial decisions, the Architect shall endeavor to secure faithful

AIA DOCUMENT B141/CMa - OWNER-ARCHITECT AGREEMENT - CONSTRUCTION MANAGER-ADVISER
EDITION - 1992 EDITION - AIA(R) - (C) 1992 - THE AMERICAN INSTITUTE OF
ARCHITECTS, 1735 NEW YORK AVENUE N.W., WASHINGTON, D.C. 20006-5292. WARNING:
Unlicensed photocopying violates U.S. copyright laws and will subject the
violator to legal prosecution. This document was electronically produced with
permission of the AIA and can be reproduced in accordance with your license
without violation until the date of expiration as noted below. User Document:
b141 01_15_ 03.aia--2/10/2003. AIA License Number 1009668, which expires on
3/28/2003.

                                                 Electronic Format B141/CMa-1992

                                                                               4
<PAGE>

performance by both Owner and Contractors, shall not show partiality to either,
and shall not be liable for results of interpretations or decisions so rendered
in good faith.

2.6.17   The Architect's decisions on matters relating to aesthetic effect shall
be final if consistent with the intent expressed in the Contract Documents,
unless a written objection is received from the Owner, which shall overrule the
decision of the Architect.

2.6.18   The Architect shall render written decisions within a reasonable time
on all claims, disputes or other matters in question between the Owner and
Contractors relating to the execution or progress of the Work as provided in the
Contract Documents.

2.6.19   The Architect's decisions on claims, disputes or other matters,
including those in question between the Owner and Contractors, except for those
relating to aesthetic effect as provided in Subparagraph 2.6.17, shall be
subject to arbitration as provided in this Agreement and in the Contract
Documents.

2.6.20   The Architect will respond to reasonable requests for information
submitted by the Contractor or others involved in the Project.

2.6.21   Owner will be provided a complete set of reproducible record drawings
and one set of Specifications ( together with a computer aided design disk
containing such Drawings and Specifications) showing all material changes in the
Work made during construction and revisions to the Drawings and Specifications
made by the Architect. Contractor shall provide record drawings to the Owner,
based on actual construction on site. Architect shall cooperate with Contractor
by providing electronic backgrounds for use by the Contractor in creating record
drawings, at no cost to the Owner or Contractor.

                                    ARTICLE 3
                               ADDITIONAL SERVICES

3.1      GENERAL

3.1.1    The services described in this Article 3 are not included in Basic
Services unless so identified in Article 12, and they shall be paid for by the
Owner as provided in this Agreement, in addition to the compensation for Basic
Services. The services described under Paragraphs 3.2 and 3.4 shall only be
provided if authorized or confirmed in writing and in advance by the Owner. If
services described under Contingent Additional Services in Paragraph 3.3 are
required due to circumstances beyond the Architect's control, the Architect
shall notify the Owner prior to commencing such services. If the Owner deems
that such services described under Paragraph 3.3 are not required, the Owner
shall give prompt written notice to the Architect. If the Owner indicates in
writing that all or part of such Contingent Additional Services are not
required, the Architect shall have no obligation to provide those services.
Provided, however, the Owner will not be required to pay and the Architect will
not be entitled to receive reimbursement or compensation for any Additional
Services or Contingent Additional Services, if such services were required due
to the fault of the Architect.

3.2      PROJECT REPRESENTATION BEYOND BASIC SERVICES

3.2.1    If more extensive representation at the site than is described in
Subparagraph 2.6.5 is required, the Architect shall provide one or more Project
Representatives to assist in carrying out such additional on-site
responsibilities.

3.2.2    Project Representatives shall be selected, employed and directed by the
Architect, and the Architect shall be compensated therefor as agreed by the
Owner and Architect. The duties, responsibilities and limitations of authority
of Project Representatives shall be as described in the edition of AIA Document
B352 current as of the date of this Agreement, unless otherwise agreed.

3.2.3    Through the observations by such Project Representatives, the Architect
shall endeavor to provide further protection for the Owner against defects and
deficiencies in the Work, but the furnishing of such project representation
shall not modify the rights, responsibilities or obligations of the Architect as
described elsewhere in this Agreement.

3.3      CONTINGENT ADDITIONAL SERVICES

3.3.1    Making revisions in Drawings, Specifications, or other documents when
such revisions are:

         .1       inconsistent with written approvals or instructions previously
                  given by the Owner, including revisions made necessary by
                  adjustments in the Owner's program or Project budget;

         .2       requested by the Owner because the Construction Manager's
                  estimate of Construction Cost exceeds the Owner's budget,
                  except where such excess is due to changes initiated by the
                  Architect in scope, capacities of basic systems, or the kinds
                  and quality of materials, finishes or equipment;

         .3       required by the enactment or revision of codes, laws or
                  regulations subsequent to the preparation of such documents;
                  or

         .4       due to changes required as a result of the Owner's failure to
                  render decisions in a timely manner provided that Owner was
                  notified at least 15 days prior thereto and given the right to
                  cure.

3.3.2    Providing services required because of significant changes in the
Project including, but not limited to, changes in size, quality, complexity, the
Owner's or Construction Manager's schedule, or the method of bidding or
negotiating

AIA DOCUMENT B141/CMa OWNER-ARCHITECT AGREEMENT - CONSTRUCTION MANAGER-ADVISER
EDITION-1992 EDITION - AIA(R)-(C)1992 -THE AMERICAN INSTITUTE OF ARCHITECTS,
1735 NEW YORK AVENUE N.W., WASHINGTON, D.C. 20006-5292. WARNING: Unlicensed
photocopying violates U.S. copyright laws and will subject the violator to legal
prosecution. This document was electronically produced with permission of the
AIA and can be reproduced in accordance with your license without violation
until the date of expiration as noted below. User Document: b141 01_15_03.aia_ -
2/10/2003. AIA License Number 1009668, which expires on 3/28/2003.

                                                 Electronic Format B141/CMa-1992

                                                                               5
<PAGE>

and contracting for construction, except for services required under
Subparagraph 5.2.3.

3.3.3    Preparing Drawings, Specifications, and other documentation and
supporting data, evaluating Contractor's reasonable alternative proposals, and
providing other services in connection with Change Orders and Construction
Change Directives, which differ from the initial scope of the Work contemplated
by the Drawings and Specifications issued for construction, except for changes
necessitated by the Architect's negligent acts, errors or omissions.

3.3.4    Providing services in connection with evaluating substitutions proposed
by Contractors and making subsequent revisions to Drawings, Specifications and
other documentation resulting therefrom.

3.3.5    Providing consultation concerning replacement of Work damaged by fire
or other cause during construction, and furnishing services required in
connection with the replacement of such Work.

3.3.6    Providing services made necessary by the termination or default of the
Construction Manager or a Contractor, by major defects or deficiencies in the
Work of a Contractor, or by failure of performance of either the Owner or a
Contractor under a Contract for Construction.

3.3.7    Providing services in evaluating an extensive number of claims
submitted by a Contractor or others in connection with changes in the scope of
the Work.

3.3.8    Providing services in connection with a public hearing, arbitration
proceeding or legal proceeding except where the Architect is party thereto.

3.3.9    Preparing documents for alternate, separate or sequential bids or
providing services in connection with bidding, negotiation or construction prior
to the completion of the Construction Documents Phase.

3.4      OPTIONAL ADDITIONAL SERVICES

3.4.2    Providing financial feasibility or other special studies.

3.4.3    Providing planning surveys, site evaluations or comparative studies of
prospective sites.

3.4.4    Providing special surveys, environmental studies and submissions
required for approvals of governmental authorities or others having jurisdiction
over the Project.

3.4.5    Providing services relative to future facilities, systems and
equipment, other than building placement studies conducted as part of site
planning.

3.4.6    Providing services to investigate existing conditions or facilities or
to make measured drawings thereof.

3.4.7    Providing services to verify the accuracy of drawings or other
information furnished by the Owner.

3.4.8    Providing coordination of construction performed by the Owner's own
forces and coordination of services required in connection with construction
performed and equipment supplied by the Owner.

3.4.9    Providing services in connection with the work of separate consultants
retained by the Owner.

3.4.10   Providing estimates of Construction Cost.

3.4.11   Providing detailed quantity surveys or inventories of material and
equipment.

3.4.12   Providing analyses of owning and operating costs,

3.4.13   Providing interior design and other similar services required for or in
connection with the selection, procurement or installation of, accessories,
furnishings and related equipment.

3.4.14   Providing services for planning tenant or rental spaces.

3.4.15   Making investigations, inventories of materials or equipment, or
valuations and detailed appraisals of existing facilities.

3.4.16   Preparing a set of reproducible record drawings showing significant
changes in the Work made during construction based on marked-up prints, drawings
and other data furnished by Contractors.

3.4.17   Providing assistance in the utilization of equipment or systems such as
testing, adjusting and balancing, preparation of operation and maintenance
manuals, training personnel for operation and maintenance, and consultation
during operation.

3.4.18   Providing services after issuance to the Owner of the final Project
Certificate for Payment, or in the absence of a final Project Certificate for
Payment, more than 60 days after the date of Substantial Completion of the Work.

3.4.19   Providing services of consultants for other than architectural, civil,
landscape, structural, mechanical and electrical engineering portions of the
Project provided as a part of Basic Services.

3.4.20   Providing any other services not otherwise included in this Agreement
or not customarily furnished in accordance with generally accepted architectural
practice.

                                    ARTICLE 4
                            OWNER'S RESPONSIBILITIES

AIA DOCUMENT B141/CMa - OWNER-ARCHITECT AGREEMENT - CONSTRUCTION
MANAGER-ADVISER EDITION - 1992 EDITION - AIA (R) - (C)1992 - THE AMERICAN
INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE N.W., WASHINGTON, D.C. 20006-5292.
WARNING: Unlicensed photocopying violates U.S. copyright laws and will subject
the violator to legal prosecution. This document was electronically produced
with permission of the AIA and can be reproduced in accordance with your license
without violation until the date of expiration as noted below. User Document:
b141 01_15_03.aia -- 2/10/2003. AIA License Number 1009668, which expires on
3/28/2003.

                                                 Electronic Format B141/CMa-1992

                                                                               6
<PAGE>

4.1      The Owner shall provide full information regarding requirements for the
Project, including a-program data which shall set forth the Owner's objectives,
schedule, constraints and criteria, including space requirements and
relationships, flexibility, expandability, special equipment, systems, and site
requirements.

4.2      The Owner shall establish and update an overall budget for the Project
based on consultation with the Construction Manager and the Architect, which
shall include the Construction Cost, the Owner's other costs and reasonable
contingencies related to all of these costs.

4.3      If requested by the Architect, the Owner shall furnish evidence that
financial arrangements have been made to fulfill the Owner's obligations under
this Agreement.

4.4      The Owner hereby designates Myron Albert as its representative
authorized to act on the Owner's behalf with respect to the Project. The Owner
or such authorized representative shall render decisions in a timely manner
pertaining to documents submitted by the Architect in order to avoid
unreasonable delay in the orderly and sequential progress of the Architect's
services.

4.5      The Owner hereby designates Koll Development Company as its
construction manager to administer the Project. The Construction Manager's
services, duties and responsibilities will be as described in the edition of AIA
Document B801/CMa, Standard Form of Agreement Between Owner and Construction
Manager, current as of the date of this Agreement. The Terms and Conditions of
the Agreement between Owner and Construction Manager shall be furnished to the
Architect and shall not be modified without written consent of the Architect,
which consent shall not be unreasonably withheld. The Architect shall not be
responsible for actions taken by the Construction Manager.

4.6      The Owner shall furnish surveys describing physical characteristics,
legal limitations and utility locations for the site of the Project, and a
written legal description of the site. The surveys and legal information shall
include, as applicable, grades and lines of streets, alleys, pavements and
adjoining property and structures; adjacent drainage; rights-of-way,
restrictions, easements, encroachments, zoning, deed restrictions, boundaries
and contours of the site; locations, dimensions and necessary data pertaining to
existing buildings, other improvements and trees; and information concerning
available utility services and lines, both public and private, above and below
grade, including inverts and depths. All the information on the survey shall be
referenced to a Project benchmark.

4.7      The Owner shall furnish the services of geotechnical engineers when
such services are requested by the Architect. Such services may include but are
not limited to lest borings, test pits, determinations of soil bearing values,
percolation, evaluations of hazardous materials, and ground corrosion and
resistivity tests, including necessary operations for anticipating subsoil
conditions, with reports and appropriate professional recommendations.

4.7.1    The Owner shall furnish the services of other consultants when such
services are reasonably required by the scope of the Project and are requested
by the Architect.

4.8      The Owner shall furnish structural, mechanical, chemical, air and water
pollution tests, tests for hazardous materials, and other laboratory and
environmental tests, inspections and reports required by law or the Contract
Documents.

4.9      The Owner shall furnish all legal, accounting, and insurance counseling
services as may be necessary at any time or the Project, including auditing
services the Owner may require to verify the Contractor's Application for
Payment or to ascertain how or for what purposes the Contractor has used the
money paid by or on behalf of the Owner.

4.10     The services, information, surveys and reports required by Paragraphs
4.6 through 4.9 shall be furnished at the Owner's expense, and the Architect
shall be entitled to rely upon the accuracy and completeness thereof. However,
the Architect will review and, as appropriate, incorporate the pertinent
information from all such services, information, surveys, and reports as part of
the Basic Services and notify Owner of any material problems or inaccuracies
observed by the Architect.

4.11     Prompt written notice shall be given by the Owner to the Architect and
Construction Manager if the Owner becomes aware of any fault or defect in the
Project or nonconformance with the Contract Documents.

4.12 The proposed language of certificates or certifications requested of the
Architect or Architect's consultants shall be submitted to the Architect for
review and approval at least 14 days prior to execution. The Owner shall not
request certifications that would require knowledge or services beyond the scope
of this Agreement.

4.13     The Owner shall furnish the required information and services and shall
render approvals and decisions as expeditiously as necessary for the orderly
progress of the Architect's services and Work of the Contractors.

4.14     The Owner shall furnish the Architect copies of written communications
with the Construction Manager and Contractors.

                                    ARTICLE 5
                                CONSTRUCTION COST

5.1      DEFINITION

5.1.1    The Construction Cost shall be the total cost or estimated cost to the
Owner of all elements of the Project designed or specified by the Architect.

AIA DOCUMENT B141/CMa - OWNER-ARCHITECT AGREEMENT - CONSTRUCTION MANAGER-ADVISER
EDITION - 1992 EDITION - AIA(R) - (c) 1992 - THE AMERICAN INSTITUTE OF
ARCHITECTS, 1735 NEW YORK AVENUE N.W., WASHINGTON, D.C. 20006-5292. WARNING:
Unlicensed photocopying violates U.S. copyright laws and will subject the
violator to legal prosecution. This document was electronically produced with
permission of the AIA and can be reproduced in accordance with your license
without violation until the date of expiration as noted below. User Document:
b141 01_15_03.aia -- 2/10/2003. AIA License Number 1009668, which expires on
3/28/2003.

                                                 Electronic Format B141/CMa-1992

                                                                               7
<PAGE>

5.1.2    The Construction Cost shall include the cost at current market rates of
labor and materials furnished by the Owner and equipment designed, specified,
selected or specially provided for by the Architect, plus a reasonable allowance
for the Contractors' overhead and profit. In addition, a reasonable allowance
for contingencies shall be included for market conditions at the time of bidding
and for changes in the Work during construction. Construction Cost shall also
include the compensation of the Construction Manager and Construction Manager's
consultants.

5.1.3    Construction Cost does not include the compensation of the Architect
and Architect's consultants, the costs of the land, rights-of-way, financing or
other costs which are the responsibility of the Owner as provided in Paragraphs
4.1 through 4.4 and 4.6 through 4.14.

5.2      RESPONSIBILITY FOR CONSTRUCTION COST

5.2.1    The Architect's review of the Owner's Project budget and of preliminary
estimates of Construction Cost or detailed estimates of Construction Cost
prepared by the Construction Manager is solely for the Architect's guidance in
the Architect's preparation of the Construction Documents. Accordingly, the
Architect cannot and does not warrant the accuracy of the estimates of the
Construction Manager, or warrant or represent that bids or negotiated prices
will not vary from the Owner's Project budget or from any estimate of
Construction Cost or evaluation reviewed by the Architect.

5.2.2    No fixed limit of Construction Cost shall be established as a condition
of this Agreement.

5.2.3    In the event that the Construction Manager's estimate or the lowest
bona fide bid or negotiated proposal received by the Owner exceeds the Owner's
budget for reasons other than those described in Paragraph 3.3, the modification
of Contract Documents shall be the limit of the Architect's responsibility. The
Architect shall be entitled to compensation in accordance with this Agreement
for all services performed whether or not the Construction Phase is commenced.

                                   ARTICLE 6
                          USE OF ARCHITECT'S DRAWINGS,
                       SPECIFICATIONS AND OTHER DOCUMENTS

6.1      The Drawings, Specifications and other documents (the "Drawings and
Specifications") prepared by the Architect for this Project are instruments of
the Architect's service for use solely with respect to this Project and, unless
otherwise provided, the Architect shall be deemed the author of these documents
and shall retain all common law, statutory and other reserved rights, including
the copyright. The Owner shall be permitted to retain copies, including
reproducible copies and computer aided design disks, of the Architect's
Drawings, Specifications and other documents for information and reference in
connection with the Owner's use and occupancy of the Project. Provided Owner is
not in breach under the terms of this Agreement, the Architect grants to the
Owner an exclusive license to reproduce the Architect's Instruments of Service
(excepting therefrom standard details from the Drawings and Specifications,
which are not unique to the Project and which Architect may use on other
projects) for purposes of construction, using and maintaining the Project,
provided that the Owner shall comply with all obligations, including prompt
payment of all sums when due, under this Agreement. The Architect shall obtain
similar exclusive licenses from the Architect's consultants consistent with this
Agreement. If this Agreement is terminated, the foregoing license shall remain
in effect and it is expressly agreed by the Architect that the Owner is
authorized to hire other similarly credentialed design professionals to
reproduce and make changes, corrections or additions to the Instruments of
Service for purposes of completing, using and maintaining the Project, and the
Architect agrees to supply necessary documentation confirming same. Owner agrees
to defend, indemnify and hold Architect harmless from any claim or liability
arising from any changes, corrections, or additions made to the Instruments of
Service by Owner or Owner's consultants.

6.2      Submission or distribution of documents to meet official regulatory
requirements or for similar purposes in connection with the Project is not to be
construed as publication in derogation of the Architect's reserved rights.

                                    ARTICLE 7
                                   ARBITRATION

7.1      Claims, disputes or other matters in question between the parties to
this Agreement arising out of or relating to this Agreement or breach thereof
shall be subject to and decided by arbitration in accordance with the
Construction Industry Arbitration Rules of the American Arbitration Association
currently in effect unless the parties mutually agree otherwise.

7.2      Demand for arbitration shall be filed in writing with the other party
to this Agreement and with the American Arbitration Association. A demand for
arbitration shall be made within a reasonable time after the claim, dispute or
other matter in question has arisen. In no event shall the demand for
arbitration be made after the date when institution of legal or equitable
proceedings based on such claim, dispute or other matter in question would be
barred by the applicable statutes of limitations.

7.3      No arbitration arising out of or relating to this Agreement shall
include, by consolidation, joinder or in any other manner, an additional person
or entity not a party to this Agreement, except by written consent containing a
specific reference to this Agreement signed by the Owner, Architect, and any
other person or entity sought to be joined. Consent to arbitration involving an
additional person or entity shall not

ATA DOCUMENT B141/CMa - OWNER-ARCHITECT AGREEMENT - CONSTRUCTION MANAGER-ADVISER
EDITION - 1992 EDITION- AIA(R) - (C) 1992 -THE AMERICAN INSTITUTE OF ARCHITECTS,
1735 NEW YORK AVENUE N.W., WASHINGTON, D.C. 20006-5292. WARNING: Unlicensed
photocopying violates U.S. copyright laws and will subject the violator to legal
prosecution. This document was electronically produced with permission of the
AIA and can be reproduced in accordance with your license without violation
until the date of expiration as noted below. User Document: b141 01_15_03.aia -
2/10/2003. AIA License Number 1009668, which expires on 3/28/2003.

                                                 Electronic Format B141/CMa-1992

                                                                               8
<PAGE>

constitute consent to arbitration of any claim, dispute or other matter in
question not described in the written consent or with a person or entity not
named or described therein. The foregoing agreement to arbitrate and other
agreements to arbitrate with an additional person or entity duly consented to by
the parties to this Agreement shall be specifically enforceable in accordance
with applicable law in any court having jurisdiction thereof. Notwithstanding
the foregoing, arbitration may involve the joinder of Construction Manager.
Contractor(s), Subcontractors), sub-subcontractor(s) and material suppliers

7.4      The award rendered by the arbitrator or arbitrators shall be final, and
judgment may be entered upon it in accordance with applicable law in any court
having jurisdiction thereof.

                                    ARTICLE 8
                     TERMINATION, SUSPENSION OR ABANDONMENT

8.1      This Agreement may be terminated by either party upon not less than
seven days' written notice should the other party fail substantially to perform
in accordance with the terms of this Agreement through no fault of the party
initiating the termination. In the event this Agreement is terminated as
provided in this Paragraph 8.1. the Architect, as its sole and exclusive remedy,
will be entitled to receive compensation for that portion of Basic and
Additional Services due for services property performed up to the date of
receipt of the termination notice and for any Reimbursable Expenses properly
incurred to the date of receipt of the termination notice.

8.2      If the Project is suspended by the Owner for more than 30 consecutive
days, the Architect shall be compensated for services performed prior to notice
of such suspension. When the Project is resumed, the Architect's compensation
shall be equitably adjusted to provide for expenses incurred in the interruption
and resumption of the Architect's services.

8.3      This Agreement may be terminated by the Owner upon not less than seven
days' written notice to the Architect,, for the Owner's convenience and without
cause. In the event this Agreement is terminated as provided in this Paragraph
8.3. the Architect, as its sole and exclusive remedy, will be entitled to
receive compensation for that portion of Basic and Additional Services due for
services properly performed up to the date of receipt of the termination notice
and for any Reimbursable Expenses properly incurred to the date of receipt of
the termination notice, which shall include any Reimbursable Expenses caused by
the termination.

8.4      Failure of the Owner to make payments to the Architect in accordance
with this Agreement shall be considered substantial nonperformance and cause for
termination.

8.5      If the Owner fails to make payment when due the Architect for services
and expenses, the Architect may, upon seven days' written notice to the Owner,
suspend performance of services under this Agreement. Unless payment in full is
received by the Architect within seven days of the date of the notice, the
suspension shall take effect without further notice. In the event of a
suspension of services, the Architect shall have no liability to the Owner for
delay or damage caused the Owner because of such suspension of services.

8.6      In the event of termination not the fault of the Architect, the
Architect shall be compensated for services properly performed performed prior
to termination, together with Reimbursable Expenses then due.

                                    ARTICLE 9
                            MISCELLANEOUS PROVISIONS

9.1      Unless otherwise provided, this Agreement shall be governed by the law
of the place where the Project is located.

9.2      Terms in this Agreement shall have the same meaning as those in the
edition of AIA Document A201/CMa, General Conditions of the Contract for
Construction, Construction Manager-Adviser Edition, current as of the date of
this Agreement.

9.3      Causes of action between the parties to this Agreement pertaining to
acts or failures to act shall be deemed to have accrued and the applicable
statutes of limitations shall commence to run not later than either the date of
Substantial Completion for acts or failures to act occurring prior to
Substantial Completion, or the date of issuance of the final Project Certificate
for Payment for acts or failures to act occurring after Substantial Completion.

AIA DOCUMENT B141/CMa - OWNER-ARCHITECT AGREEMENT - CONSTRUCTION MANAGER-ADVISER
EDITION - 1992 EDITION - AIA (R) - (c) 1992 -THE AMERICAN INSTITUTE OF
ARCHITECTS, 1735 NEW YORK AVENUE N.W., WASHINGTON, D.C. 20006-5292. WARNING:
Unlicensed photocopying violates U.S. copyright laws and will subject the
violator to legal prosecution. This document was electronically produced with
permission of the AIA and can be reproduced in accordance with your license
without violation until the date of expiration as noted below. User Document:
b141 01_15_03.aia -- 2/10/2003. AIA License Number 1009668, which expires on
3/28/2003.

                                                 Electronic Format B141/CMa-1992

                                                                               9
<PAGE>

9.4      The Owner and Architect waive all rights against each other and against
the Construction Manager, Contractors, and the consultants, agents and employees
of any of them for damages, but only to the extent covered by property insurance
during construction, except such rights as they may have to the proceeds of such
insurance as set forth in the edition of AIA Document A201/CMa, General
Conditions of the Contract for Construction, Construction Manager-Adviser
Edition, current as of the date of this Agreement. The Owner and Architect each
shall require similar waivers from their Construction Manager, Contractors,
consultants, agents, and persons or entities awarded separate contracts
administered under the Owner's own forces.

9.5      The Owner and Architect, respectively, bind themselves, their partners,
successors, assigns and legal representatives to the other party to this
Agreement and to the partners, successors, assigns and legal representatives of
such other party with respect to all covenants of this Agreement. Neither Owner
nor Architect shall assign this Agreement without the written consent of the
other.

9.6      This Agreement represents the entire and integrated agreement between
the Owner and Architect and supersedes all prior negotiations, representations
or agreements, either written or oral. This Agreement may be amended only by
written instrument signed by both Owner and Architect.

9.7      Nothing contained in the Agreement shall create a contractual
relationship with or a cause of action in favor of a third party against either
the Owner or Architect.

9.8      Unless otherwise provided in this Agreement, the Architect and
Architect's consultants shall have no responsibility for the discovery,
presence, handling, removal or disposal of or exposure of persons to hazardous
materials in any form at the Project site, including but not limited to
asbestos, asbestos products, polychlorinated biphenyl (PCB) or other toxic
substances.

9.9      The Architect shall not have the right to include representations of
the design of the Project, including photographs of the exterior and interior,
among the Architect's promotional and professional materials without the Owner's
express written consent, which may be withheld at Owner's sole discretion. The
Architect's materials shall not include the Owner's confidential or proprietary
information if the Owner has previously advised the Architect in writing of the
specific information considered by the Owner to be confidential or proprietary.
The Owner shall provide professional credit for the Architect on the
construction sign and in the promotional materials for the Project.

                                   ARTICLE 10
                            PAYMENTS TO THE ARCHITECT

10.1     DIRECT PERSONNEL EXPENSE

10.1.1   Direct Personnel Expense is defined as the direct salaries of the
Architect's personnel engaged on the Project and the portion of the cost of
their mandatory and customary contributions and benefits related thereto, such
as employment taxes and other statutory employee benefits, insurance, sick
leave, holidays, vacations, pensions and similar contributions and benefits.

10.2     REIMBURSABLE EXPENSES

10.2.1   Reimbursable Expenses are in addition to compensation for Basic and
Additional Services and include reasonable expenses incurred by the Architect
and Architect's employees and consultants in the interest of the Project, as
identified in the following Clauses.

10.2.1.1 Expense of transportation in excess of 50 miles in connection with the
Project; expenses in connection with authorized out-of-town travel;
long-distance communications; and fees paid for securing approval of authorities
having jurisdiction over the Project.

10.2.1.2 Expense of plots, reproductions, postage, express deliveries,
electronic facsimile transmissions and handling of Drawings, Specifications and
other documents.

10.2.1.3 If authorized in advance by the Owner, expense of overtime work
requiring higher than regular rales.

10.2.1.4 Expense of renderings, models and mock-ups requested by the Owner.

10.2.1.5 Expense of additional insurance coverage or limits, including
professional liability insurance, requested by the Owner in excess of that
normally carried by the Architect and Architect's consultants.

10.2.1.6 Expense of computer-aided design and drafting equipment lime when used
in connection with the Project

10.2.1.7 Taxes on goods or services.

10.2.1.8 The Architect understands that the Owner has established a $45,000
budget for reimbursable items and Architect commits to work with Owner to
achieve this goal, with the understanding that not all factors can be
anticipated at the time of this agreement; however, this amount will not be
exceeded without Owner's prior written approval.

10.3     PAYMENTS ON ACCOUNT OF BASIC SERVICES

10.3.1   An initial payment as set forth in Paragraph 11.1 is the minimum
         payment under this Agreement.

10.3.2   Subsequent payments for Basic Services shall be made monthly and, where
applicable, shall be in proportion to services performed within each phase type
of service, on the basis set forth in Subparagraph 11.2.1.

AIA DOCUMENT B141/CMa - OWNER-ARCHITECT AGREEMENT - CONSTRUCTION MANAGER-ADVISER
EDITION - 1992 EDITION - AIA(R) - (C) 1992 -THE AMERICAN INSTITUTE OF
ARCHITECTS, 1735 NEW YORK AVENUE N.W., WASHINGTON, D.C. 20006-5292. WARNING:
Unlicensed photocopying violates U.S. copyright laws and will subject the
violator to legal prosecution. This document was electronically produced with
permission of the AIA and can be reproduced in accordance with your license
without violation until the dale of expiration as noted below. User Document:
bl41 01_15_03.aia - 2/10/2003. AIA License Number 1009668, which expires on
3/28/2003.

                                                 Electronic Format B141/CMa-1992

                                                                              10
<PAGE>

10.3.3   If and to the extent that the time initially established in
Subparagraph 11.5.1 of this Agreement is exceeded or extended through no fault
of the Architect, compensation for any services rendered during the additional
period of time shall be computed in the manner set forth in Subparagraph 11.3.2.

10.3.4   When compensation is based on a percentage of Construction Cost and any
portions of the Project are deleted or otherwise not constructed, compensation
for those portions of the Project shall be payable to the extent services are
performed on those portions, in accordance with the schedule set forth in
Subparagraph 11.1.2, based on (I) the lowest bona fide bids or negotiated
proposals, or (2) if no such bids or proposals are received, the most recent
estimate of Construction Cost prepared by the Construction Manager for such
portions of the Project.

10.4     PAYMENTS ON ACCOUNT OF ADDITIONAL SERVICES AND REIMBURSABLE EXPENSES

10.4.1   Payments on account of the Architect's Additional Services and for
Reimbursable Expenses shall be made  within 30 days of the proper presentation
of the Architect's statement of services rendered or expenses incurred,
including all supporting and back-up invoices and documentation requested by
Owner.

10.5     PAYMENTS WITHHELD

10.5.1   No deductions shall be made from the Architect's compensation on
account of penalty, liquidated damages or other sums withheld from payments to
Contractors, or on account of the cost of changes in the Work other than those
for which the Architect has been found to be liable.

10.6     ARCHITECT'S ACCOUNTING RECORDS

10.6.1   Records of Reimbursable Expenses and expenses pertaining to Additional
Services and services performed on the basis of a multiple of Direct Personnel
Expense shall be available to the Owner or the Owner's authorized representative
at mutually convenient times.

                                   ARTICLE 11
                              BASIS OF COMPENSATION

The Owner shall compensate the Architect as follows:

11.1     AN INITIAL PAYMENT of zero Dollars ($ -0- ) shall be made upon
execution of this Agreement and credited to the Owner's account at final
payment.

11.2     BASIC COMPENSATION

11.2.1   FOR BASIC SERVICES, as described in Article 2, and any other services
included in Article 12 as part of Basic Services, Basic Compensation shall be a
Fixed Fee, not to exceed the following amounts for each phase of the Work:

(Insert basis of compensation, including stipulated sums, multiples or
percentages, and identify phases to which particular methods of compensation
apply, if necessary.)

<TABLE>
<CAPTION>
           Phase                                     Fee
           -----                                   -------
<S>                                                <C>
Programming (Architectural)                         10,000
Programming (Consultants)                            8,200
SHELL SERVICES
Schematic Design                                    43,718
Design Development                                  60,530
Construction Documents                             161,405
Bidding                                              6,725
Construction Administration                         63,890
INTERIOR SERVICES
Schematic Design                                    38,925
Design Development                                  43,248
Construction Documents                              90,820
Bidding                                              6,487
Construction Administration                         36,760
Furniture Services                                  20,500
Move Support                                         9,000
</TABLE>

AIA DOCUMENT B141/CMa - OWNER-ARCHITECT AGREEMENT - CONSTRUCTION MANAGER-ADVISER
EDITION - 1992 EDITION - AIA(R) - (C) 1992 - THE AMERICAN INSTITUTE OF
ARCHITECTS, 1735 NEW YORK AVENUE N.W., WASHINGTON, D.C. 20006-5292. WARNING:
Unlicensed photocopying violates U.S. copyright laws and will subject the
violator to legal prosecution. This document was electronically produced with
permission of the AIA and can be reproduced in accordance with your license
without violation until the date of expiration as noted below. User Document:
b141 01_15_03.aia - 2/10/2003. AIA License Number 1009668, which expires on
3/28/2003.

                                                 Electronic Format B141/CMa-1992

                                                                              11
<PAGE>

<TABLE>
<S>                                            <C>
OPTIONAL SERVICES
See Article 12
Master Planning                                   3,500
Food service                                      7,370
Lighting                                          9,110
Audio/Visual                                      8,450
Acoustical                                        3,960
Structural Ground Floor                          10,090
                                                -------
   Total                                       $ 42,480
                                                =======
</TABLE>

11.3     COMPENSATION FOR ADDITIONAL SERVICES

11.3.1   FOR PROJECT REPRESENTATION BEYOND BASIC SERVICES, as described in
Paragraph 3.2, compensation shall be computed as follows:

            Hourly rates equal to:
                Senior Principals:     $150.00
                Employees:             Two and Eighty-Five One-Hundredths
                                       (2.85) times Direct Personnel Expense

            For the purpose of this Agreement the Senior Principals are:
            R. Lawrence Good, FAIA; Duncan T. Fulton, FA1A;

            David M. Farrell, A1A; Joseph J. Patti, AIA. CS1: and Bryce A.
            Weigand, FAIA

11.3.2   FOR ADDITIONAL SERVICES OF THE ARCHITECT, as described in Articles 3
and 12, other than (i) Additional Project Representation, as described in
Paragraph 3.2, and (2) services included in Article 12 as part of Basic
Services, but excluding services of consultants, compensation shall be computed
as follows:

(Insert basis of compensation, including rates and/or multiples of Direct
Personnel Expense for Principals and employees, and identify Principals and
classify employees, if required. Identify specific services to which particular
methods of compensation apply, if necessary,)

            Hourly rates equal to:

                Senior Principals:     $150.00
                Employees:             Two and Eighty-Five One-Hundredths
                                       (2.85) times Direct Personnel Expense

            For the purpose of this Agreement the Senior Principals are;
            R. Lawrence Good, FAIA; Duncan T. Fulton, FAIA;

            David M. Farrell, AIA; Joseph J. Patti. AIA. CSI: and Bryce A.
            Weigand, FAIA

11.3.3   FOR ADDITIONAL SERVICES OF CONSULTANTS, including additional
structural, mechanical and electrical engineering services and those provided
under Subparagraph 3.4.19 or identified in Article 12 as part of Additional
Services, a multiple of One and One-Tenth ( 1.10) times the amounts billed to
the Architect for such services.

(Identify specific types of consultants in Article 12, if required.)

11.4     REIMBURSABLE EXPENSES

11.4.1   FOR REIMBURSABLE EXPENSES, as described in Paragraph 10.2, and any
other items included in Article 12 as Reimbursable Expenses, a multiple of one
and one tenth (1.10 ) times the expenses incurred by the Architect, the
Architect's employees and consultants in the interest of the Project.

11.5     ADDITIONAL PROVISIONS

11.5.1   IF THE BASIC SERVICES covered by this Agreement have not been completed
         within twelve (12) months of the date

AIA DOCUMENT B141/CMa - OWNER-ARCHITECT AGREEMENT - CONSTRUCTION MANAGER-ADVISER
EDITION - 1992 EDITION - AIA(R) - (c) 1992 - THE AMERICAN INSTITUTE OF
ARCHITECTS, 1735 NEW YORK AVENUE N.W., WASHINGTON, D.C. 20006-5292. WARNING:
Unlicensed photocopying violates U.S. copyright laws and will subject the
violator to legal prosecution. This document was electronically produced with
permission of the AIA and can be reproduced in accordance with your license
without violation until the date of expiration as noted below. User Document:
b141 01_15_03.aia -- 2/10/2003. AIA License Number 1009668, which expires on
3/28/2003.

                                                 Electronic Format B141/CMa-1992

                                                                              12
<PAGE>

hereof, through no fault of the Architect, extension of the Architect's services
beyond that time shall be compensated as provided in Subparagraphs 10.3.3 and
11.3.2.

11.5.2   Payments are due and payable thirty (30 ) days from the date of the
Architect's invoice. Amounts unpaid thirty ( 30) days after the invoice date
shall bear interest at the rate entered below, or in the absence thereof at the
legal rate prevailing from time to time at the principal place of business of
the Architect.

(Insert rate of interest agreed upon.)

1.25% per month

(Usury laws and requirements under the Federal Truth in Lending Act, similar
state and local consumer credit laws and other regulations at the Owner's and
Architect's principal places of business, the location of the Project and
elsewhere may affect the validity of this provision. Specific legal advice
should be obtained with respect to deletions or modifications, and also
regarding requirements such as written disclosures or waivers.)

11.5.3   The rates and multiples set forth for Additional Services shall be
annually adjusted in accordance with normal salary review practices of the
Architect.

                                   ARTICLE 12
                          OTHER CONDITIONS OR SERVICES

(Insert descriptions of other services, identify Additional Services included
within Basic Compensation, and insert modifications to the payment and
compensation terms included in this Agreement.)

         12.1     The following Optional Services,for the Fixed Fee set forth
         in Paragraph 11.2.1, may be required by the Owner, subject to written
         authorization from the Owner:

                  Master Planning
                  Food Service Consulting
                  Lighting Consulting
                  Audio Visual Consulting
                  Acoustical Consulting

         12.1.1   Master Planning shall consist of evaluating building
         footprint, parking placement, and other conceptual site lay out issues.
         The final deliverable from the Master Planning shall be a conceptual
         color site plan illustrating the preferred option.

         12.1.2   Food Service consulting shall consist of conceptual kitchen
         planning through Design Development to assess the infrastructure
         requirements (primarily utility, exhaust, and space requirements) for a
         2,000 S.F. kitchen /serving area, in order to design the shell to
         receive such facilities at a future date. In the event finish out
         construction documents are prepared for this area, the fees for such
         services shall be in addition to the Optional Fees set forth above.

         12.1.3   Lighting Consulting shall be for the Board Room, Amphitheater,
         Lobby, Sales Training Room, and Library Museum.

         12.1.4   Audio Visual Consulting Services shall be for the Sales
         Training Room. Amphitheater, Board Room, and the Cold OR.

         12.1.5   Architectural Acoustic consulting shall be for the
         Amphitheater, Board Room, and Sales Training Room.

         12.2     Basic Services are based on issuing a total of two (2) interim
         pricing packages and two (2) construction document packages; a shell
         package followed by interiors package with the two being produced
         sequentially by the same staff without any interruption.

         12.3     The Fixed Fee for Basic Services assumes a 46 week aggregate
         shell and interiors construction period through Substantial Completion,
         followed by a 4-week punch list /closeout period through final
         completion, with the same general contractor performing both the shell
         and interior construction. In the event separate shell and interior
         general contractors are selected, the additional services required to
         administer an additional contract shall be considered an Additional
         Service. If, through no fault of Architect, the aggregate construction
         period exceeds 46 weeks and such extension materially increases the
         Architect's obligations under Basic Services, such additional services
         shall be considered an Additional Service. No Additional Services shall
         be provided without the Owner's written approval in advance of any such
         services.

         12.4     Code required signage is included, however, all other signage,
         such as a project identification signage, shall be provided as an
         Additional Service.

         12.5     Basic Services include the necessary services to accommodate
         a 20,000 S.F. Clean Room into the shell. Consistent with customary
         practice when a self-contained specialty area is incorporated into a
         project (such as kitchens, data centers and the like), services
         required exclusively for the Clean Room, such as process flow planning,
         internal FF & E planning and the like will be provided by Owner's
         Clean Room Consultant.

         12.6     Civil engineering services which are included as a Basic
         Service arc on-site grading, and on-site utility plan only.

         12.7     Platting and platting assistance are not included as a Basic
         Service.

         12.8     Services regarding trenching operations are not included as
         part of this Agreement. This includes, but is not limited to, trench
         design, trench shoring design, consultation regarding trenching,
         observation of trenching operations. The Owner agrees to require the
         Contractor to make all provisions for trenching operations.

AIA DOCUMENT B141/CMa - OWNER-ARCHITECT AGREEMENT - CONSTRUCTION MANAGER-ADVISER
EDITION - 1992 EDITION - AIA(R) - (c) 1992 -THE AMERICAN INSTITUTE OF
ARCHITECTS, 1735 NEW YORK AVENUE N.W., WASHINGTON, D.C. 20006-5292. WARNING:
Unlicensed photocopying violates U.S. copyright laws and will subject the
violator to legal prosecution. This document was electronically produced with
permission of the AIA and can be reproduced in accordance with your license
without violation until the date of expiration as noted below. User Document:
b141 01_15_03.aia -- 2/10/2003. AIA License Number 1009668, which expires on
3/28/2003.

                                                 Electronic Format B141/CMa-1992

                                                                              13
<PAGE>

         12.9     The Owner has, or will, retain via separate contract,
         qualified professionals to assess the property for hazardous materials
         (including providing an asbestos survey stipulated in the Texas
         Asbestos Health Protection Act) and removing any slich substance. As
         such, the Architect shall consider the building and site free of
         hazardous substances for the purposes of performing Architect's
         services.

         12.10    The Architect shall have the right to rely on the accuracy,
         thoroughness and completeness of all information provided by the Owner.
         Owner's Representative(s), or Construction Manager(s) including
         pricing, schedule, or other information provided by the contractor,
         construction/cost advisor or similar party during all phases of the
         project, including pre-construction. However. Architect will review all
         such information as part of the Basic Services and notify Owner of any
         observed problems or inaccuracies.

         12.11    The Owner agrees to limit the Architect's liability to the
         Owner due to the Architect's negligent acts, errors, or omission, such
         that the total aggregate liability of the Architect to all those named
         shall not exceed One Million Dollars ($1,000,000). Provided, however,
         Architect shall maintain Errors & Omission insurance coverage of not
         less than One Million Dollars ( $ 1,000,000), in full force and effect
         at all times services are being provided in connection with the
         Project, and continuing for a minimum of two years following final
         Completion of the Project.

         12.12    In the event the Owner ejects to divide the project into
         multiple packages to accelerate the construction process, the Owner
         acknowledges this entails certain inherent risks. These include, but
         are not limited to, the inability to coordinate early release work
         with that of Iater packages, an increased incidence of change orders
         and field coordination changes, incomplete code interpretations and
         work in progress modification. By utilizing multiple packages, the
         Owner agrees to accept these risks in order to achieve the benefits of
         reduced construction time.

         12.13    The Texas Board of Architectural Examiners, 333 Guadalupe,
         Suite 2-350, Austin, TX 78701-3942, Phone: 512/305-9000, has
         jurisdiction over individuals licensed under the Architects
         Registration Law, Article 249A, VTCS

This Agreement entered into as of the day and year first written above.
/s/ F. ROBERT MERRILL                    /s/ DUNCAN T. FULTON
-----------------------------------      ---------------------------------------
OWNER (Signature)                        ARCHITECT (Signature)

F. ROBERT MERRILL                        DUNCAN T. FULTON, FAIA
EXECUTIVE VICE PRESIDENT, CFO            VICE PRESIDENT, GOOD FULTON & Farrell
                                         Architects

(Printed name and title)                 (Printed name and title)

AIA DOCUMENT B141/CMa - OWNER-ARCHITECT AGREEMENT - CONSTRUCTION MANAGER-ADVISER
EDITION - 1992 EDITION - AIA(R)-(C) 1992 - THE AMERICAN INSTITUTE OF ARCHITECTS,
1735 NEW YORK AVENUE N.W., WASHINGTON, D.C. 20006-5292. WARNING: Unlicensed
photocopying violates U.S. copyright laws and will subject the violator to legal
prosecution. This document was electronically produced with permission of the
AIA and can be reproduced in accordance with your license without violation
until the date of expiration as noted below. User Document: b141 01_15_03.aia -
2/10/2003. AIA License Number 1009668, which expires on 3/28/2003.

                                                 Electronic Format B141/CMa-1992

                                                                              14<PAGE>

                                                                   EXHIBIT 10.25

                    AIA Document B801/CMa - Electronic Format

                       Standard Form of Agreement Between
                         Owner and Construction Manager

               where the Construction Manager is NOT a Constructor

                                  1992 Edition

THIS DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES; CONSULTATION WITH AN ATTORNEY IS
ENCOURAGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION. AUTHENTICATION OF
THIS ELECTRONICALLY DRAFTED AIA DOCUMENT MAY BE MADE BY USING AIA DOCUMENT D401.

This document is intended to be used in conjunction with the 1992 editions of
AIA Documents B141/CMa, A101/CMa and A201/CMa.

Copyright 1973, 1980, (C) 1992 by The American Institute of Architects, 1735 New
York Avenue, N.W., Washington, D.C., 20006-5292. Reproduction of the material
herein or substantial quotation of its provisions without written permission of
the AIA violates the copyright laws of the United States and will subject the
violator to legal prosecution.

AGREEMENT
made as of the Fifteen day of October in the year of Two Thousand Two
(In words, indicate day, month and year)

BETWEEN the Owner:
(Name and address)
Advanced Neuromodulation Systems, Inc.
6501 Windcrest Drive, Suite #100
Plano, TX 75024

and the Construction Manager:
(Name and address)
Koll Development Company
8411 Preston Rd., Suite #700
Dallas, TX 75225

for the following Project:
(Include detailed description of Project, location, address and scope.)
Advanced Neuromodulation Systems, Inc.
at Legacy Business Park
Preston Rd. at Tennyson Drive
Plano, TX 75024

The Architect is:
(Name and address)

Good, Fulton & Farrell Architects
2808 Fairmount Street, Suite #300
Dallas, TX 75201

The Owner and Construction Manager agree as set forth below.

    Terms and Conditions of Agreement Between Owner and Construction Manager

                                    ARTICLE 1
                     CONSTRUCTION MANAGER'S RESPONSIBILITIES

1.1      CONSTRUCTION MANAGER'S SERVICES

(C)1992 - THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W.,
WASHINGTON, D.C. 20006-5292. AIA DOCUMENT B801/CMa - OWNER-CONSTRUCTION MANAGER
AGREEMENT - 1992 EDITION - AIA(R)- WARNING: Unlicensed photocopying violates
U.S. copyright laws and will subject the violator to legal prosecution. This
document was electronically produced with permission of the AIA and can be
reproduced in accordance with your license without violation until the date of
expiration as noted below. expiration as noted below, expiration as noted below,
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below. User Document: b801 dev agr apr uyya -- 4/9/2003. AIA
License Number 1768076504, which expires on 10/30/2003.

                                                 Electronic Format B801/CMa-1992

                                                                               1
<PAGE>

1.1.1    The Construction Manager's services consist of those services performed
by the Construction Manager, Construction Manager's employees and Construction
Manager's consultants as enumerated in Articles 2 and 3 of this Agreement and
any other services included in Article 14.

1.1.2    The Construction Manager's services shall be provided in conjunction
with the services of an Architect as described in the edition of AIA Document
B141/CMa, Standard Form of Agreement Between Owner and Architect, Construction
Manager-Adviser Edition, current as of the dale of this Agreement.

1.1.3    The Construction Manager shall provide sufficient organization,
personnel and management to carry out the requirements of this Agreement in an
expeditious and economical manner consistent with the interests of the Owner.

1.1.4    The services covered by this Agreement are subject to the lime
limitations contained in Subparagraph 13.5.1.

                                    ARTICLE 2
                 SCOPE OF CONSTRUCTION MANAGER'S BASIC SERVICES

2.1      DEFINITION

2.1.1    The Construction Manager's Basic Services consist of those described in
Paragraphs 2.2 and 2.3 and any other services identified in Article 14 as part
of Basic Services - including those further described in Exhibit A - CM Services
Responsibility Matrix.

2.2      PRE-CONSTRUCTION PHASE

2.2.1    The Construction Manager shall review the program furnished by the
Owner to ascertain the requirements of the Project and shall arrive at a mutual
understanding of such requirements with the Owner.

2.2.2    The Construction Manager shall provide a preliminary evaluation of the
Owner's program, schedule and construction budget requirements, each in terms of
the other.

2.2.3    Based on early schematic designs and other design criteria prepared by
the Architect, the Construction Manager shall prepare preliminary estimates of
Construction Cost for program requirements using area, volume or similar
conceptual estimating techniques. The Construction Manager shall provide cost
evaluations of alternative materials and systems.

2.2.4    The Construction Manager shall expeditiously review design documents
during their development and advise on proposed site use and improvements,
selection of materials, building systems and equipment, and methods of Project
delivery. The Construction Manager shall provide recommendations on relative
feasibility of construction methods, availability of materials and labor, time
requirements for procurement, installation and construction, and factors related
to construction cost including, but not limited to, costs of alternative designs
or materials, preliminary budgets, and possible economies.

2.2.5    The Construction Manager shall prepare and periodically update a
Project Schedule for the Architect's review and the Owner's acceptance. The
Construction Manager shall obtain the Architect's approval for the portion of
the preliminary project schedule relating to the performance of the Architect's
services. In the Project Schedule, the Construction Manager shall coordinate and
integrate the Construction Manager's services, the Architect's services and the
Owner's responsibilities with anticipated construction schedules, highlighting
critical and long-lead-time items.

2.2.6    As the Architect progress with the preparation of the Schematic, Design
Development and Construction Documents, the Construction Manager shall prepare
and update, at appropriate intervals agreed to by the Owner, Construction
Manager and Architect, estimates of Construction Cost of increasing detail and
refinement. The estimated cost of each Contract shall be indicated with
supporting detail. Such estimates shall be provided for the Architect's review
and the Owner's approval. The Construction Manager shall advise the Owner and
Architect if it appears that the Construction Cost may exceed the latest
approved Project budget and make recommendations for corrective action.

2.2.7    The Construction Manager shall consult with the Owner and Architect
regarding the Construction Documents and make recommendations whenever design
details adversely affect constructibility, cost or schedules.

2.2.8    The Construction Manager shall provide recommendations and information
to the Owner and Architect regarding the assignment of responsibilities for
temporary Project facilities and equipment, materials and services for common
use of the Contractors. The Construction Manager shall verify that such
requirements and assignment of responsibilities are included in the proposed
Contract Documents.

2.2.9    The Construction Manager shall provide recommendations and information
to the Owner regarding the allocation of responsibilities for safety programs
among the Contractors.

2.2.10   The Construction Manager shall advise on the division of the Project
into individual Contracts for various categories of Work, including the method
to be used for selecting Contractors and awarding Contracts. If multiple
Contracts are to be awarded, the Construction Manager shall review the
Construction Documents and make recommendations as required to provide that (1)
the Work of the Contractors is coordinated, (2) all requirements for the Project
have been assigned to the appropriate Contract, (3) the likelihood of
jurisdictional disputes has been minimized, and (4) proper coordination has been
provided for phased construction.

(C)1992 - THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W.,
WASHINGTON, D.C- 20006-5292. AIA DOCUMENT B801/CMa - OWNER-CONSTRUCTION MANAGER
AGREEMENT - 1992 EDITION - AIA(R)- WARNING: Unlicensed photocopying violates
U.S. copyright laws and will subject the violator to legal prosecution. This
document was electronically produced with permission of the AIA and can be
reproduced in accordance with your license without violation until the date of
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below. User Document: b801 dev agr apr uyya - 4/9/2003. AIA
License Number 1768076504, which expires on 10/30/2003.

                                                 Electronic Format B801/CMa-1992

                                                                               2
<PAGE>

2.2.11   The Construction Manager shall prepare a Project construction schedule
providing for the components of the Work, including phasing of construction,
times of commencement and completion required of each Contractor, ordering and
delivery of products requiring long lead time, and the occupancy requirements of
the Owner. The Construction Manager shall provide the current Project
construction schedule for each set of bidding documents.

2.2.12   The Construction Manager shall expedite and coordinate the ordering and
delivery of materials requiring long lead time- through each Contractor.

2.2.13   The Construction Manager shall assist the Owner in selecting, retaining
and coordinating the professional services of surveyors, special consultants and
testing laboratories required for the Project.

2.2.14   The Construction Manager shall provide an analysis of the types and
quantities of labor required for the Project and review the availability of
appropriate categories of labor required for critical phases. The Construction
Manager shall make recommendations for actions designed to minimize adverse
effects of labor shortages.

2.2.15   The Construction Manager shall assist the Owner in obtaining
information regarding applicable requirements for equal employment opportunity
programs for inclusion in the Contract Documents.

2.2.16   Following the Owner's approval of the Construction Documents, the
Construction Manager shall update and submit the latest estimate of Construction
Cost and the Project construction schedule for the Architect's review and the
Owner's approval.

2.2.17   The Construction Manager shall submit the list of prospective bidders
for the Architect's review and the Owner's approval.

2.2.18   The Construction Manager shall develop bidders' interest in the Project
and establish bidding schedules. The Construction Manager, with the assistance
of the Architect, shall issue bidding documents to bidders and conduct prebid
conferences with prospective bidders. The Construction Manager shall assist the
Architect with regard to questions from bidders and with the issuance of
addenda.

2.2.19   The Construction Manager shall receive bids, prepare bid analyses and
make recommendations to the Owner for the Owner's award of Contracts or
rejection of bids.

2.2.20   The Construction Manager shall assist the Owner in preparing
Construction Contracts and advise the Owner on the acceptability of
Subcontractors and material suppliers proposed by Contractors.

2.2.21   The Construction Manager shall assist the Owner and Contractor in
obtaining building permits and special permits for permanent improvements,
except for permits required to be obtained directly by the various Contractors.
The Construction Manager shall verify that the Owner has paid applicable fees
and assessments. The Construction Manager shall assist the Owner and Architect
in connection with the Owner's responsibility for filing documents required for
the approvals of governmental authorities having jurisdiction over the Project.

2.3      CONSTRUCTION PHASE-ADMINISTRATION OF THE CONSTRUCTION CONTRACT

2.3.1    The Construction Phase will commence with the award of the initial
Construction Contract or purchase order and, together with the Construction
Manager's obligation to provide Basic Services under this Agreement, will end 30
days after final payment to all Contractors is due.

2.3.2    The Construction Manager shall provide administration of the Contracts
for Construction in cooperation with the Architect as set forth below and in the
modified version of the edition of AIA Document A201/CMa, General Conditions of
the Contract for Construction, Construction Manager-Adviser Edition, as agreed
upon between the Owner and Construction Manger.

2.3.3    The Construction Manager shall provide administrative, management and
related services to coordinate scheduled activities and responsibilities of the
Contractors with each other and with those of the Construction Manager, the
Owner and the Architect to endeavor to manage the Project in accordance with the
latest approved estimate of Construction Cost, the Project Schedule and the
Contract Documents

2.3.4    The Construction Manager shall schedule and conduct meetings to discuss
such matters as procedures, progress and scheduling. The Construction Manager
shall prepare and promptly distribute minutes to the Owner, Architect and
Contractors.

2.3.5    Utilizing the Construction Schedules provided by the Contractors, the
Construction Manager shall update the Project construction schedule
incorporating the activities of the Contractors on the Project, including
activity sequences and durations, allocation of labor and materials, processing
of Shop Drawings, Product Data and Samples, and delivery of products requiring
long lead time and procurement. The Project construction schedule shall include
the Owner's occupancy requirements showing portions of the Project having
occupancy priority. The Construction Manager shall update and reissue the
Project construction schedule as required to show current conditions. If an
update indicates that the previously approved Project construction schedule may
not be met, the Construction Manager shall recommend corrective action to the
Owner and Architect.

2.3.6    Consistent with the various bidding documents, and utilizing
information from the Contractors, the Construction Manager shall coordinate the
sequence of construction and assignment of space in areas where the Contractors
are performing Work.

(C) 1992 - THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W.,
WASHINGTON, D.C. 20006-5292. AIA DOCUMENT B801/CMa - OWNER-CONSTRUCTION MANAGER
AGREEMENT - 1992 EDITION - AIA(R) - WARNING: Unlicensed photocopying violates
U.S. copyright laws and will subject the violator to legal prosecution. This
document was electronically produced with permission of the AIA and can be
reproduced in accordance with your license without violation until the date of
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below. User Document: b801 dev agr apr uyya -- 4/9/2003. AIA
License Number 1768076504, which expires on 10/30/2003,

                                                 Electronic Format B801/CMa-1992

                                                                               3
<PAGE>

2.3.7    The Construction Manager shall endeavor to obtain satisfactory
performance from each of the Contractors. The Construction Manager shall
recommend courses of action to the Owner when requirements of a Contract are not
being fulfilled.

2.3.8    The Construction Manager shall monitor the approved estimate of
Construction Cost. The Construction Manager shall show actual costs for
activities in progress and estimates for uncompleted tasks by way of comparison
with such approved estimate.

2.3.9    The Construction Manager shall develop cash flow reports and forecasts
for the Project and advise the Owner and Architect as to variances between
actual and budgeted or estimated costs.

2.3.10   The Construction Manager shall maintain accounting records on
authorized Work performed under unit costs, additional Work performed on the
basis of actual costs of labor and materials, and other Work requiring
accounting records.

2.3.11   The Construction Manager shall develop and implement procedures for the
review and processing of applications by Contractors for progress and final
payments.

2.3.11.1 Based on the Construction Manager's observations and evaluations of
each Contractor's Application for Payment, the Construction Manager shall review
and certify the amounts due the respective Contractors.

2.3.11.2 The Construction Manager shall assemble and prepare  the Project
Application(s) for Payment based on the Contractors' Certificates for Payment.

2.3.11.3 The Construction Manager's certification for payment shall constitute a
representation to the Owner, based on the Construction Manager's determinations
at the site as provided in Subparagraph 2.3.13 and on the data comprising the
Contractors' Applications for Payment, that, to the best of the Construction
Manager's knowledge, information and belief, the Work has progressed to the
point indicated and the quality of the Work is in accordance with the Contract
Documents. The foregoing representations are subject to an evaluation of the
Work for conformance with the Contract Documents upon Substantial Completion, to
results of subsequent tests and inspections, to minor deviations from the
Contract Documents correctable prior to completion and to specific
qualifications expressed by the Construction Manager. The issuance of a
Certificate for Payment shall further constitute a representation that the
Contractor is entitled to payment in the amount certified.

2.3.11.4 The issuance of a Certificate for Payment shall be a representation
that the Construction Manager has (1) made or reasonable and continuous on-site
inspections to check the quality or quantity of the Work, (2) reviewed
construction means, methods, techniques, sequences for the Contractor's own
Work, or procedures, (3) reviewed copies of requisitions received from
Subcontractors and material suppliers and other data requested by the Owner to
substantiate the Contractor's right to payment and (4) ascertained for what
purpose the Contractor has used money previously paid on account of the Contract
Sum by means of review of pertinent lien waiver documentation.

2.3.12   The Construction Manager shall review the safety programs developed by
each of the Contractors for purposes of coordinating the safety programs with
those of the other Contractors. The Construction Manager's responsibilities for
coordination of safety programs shall not extend to direct control over or
charge of the acts or omissions of the Contractors, Subcontractors, agents or
employees of the Contractors or Subcontractors, or any other persons performing
portions of the Work and not directly employed by the Construction Manager.

2.3.13 The Construction Manager shall determine in general that the Work of each
Contractor is being performed in accordance with the requirements of the
Contract Documents, endeavoring to guard the Owner against defects and
deficiencies in the Work. As appropriate, the Construction Manager shall have
authority, upon written authorization from the Owner, to require additional
inspection or testing of the Work in accordance with the provisions of the
Contract Documents, whether or not such Work is fabricated, installed or
completed. The Construction Manager, in consultation with the Architect and
Owner, may reject Work which does not conform to the requirements of the
Contract Documents.

2.3.14   The Construction Manager shall schedule and coordinate the sequence of
construction in accordance with the Contract Documents and the latest approved
Project construction schedule.

2.3.15   With respect to each Contractor's own Work, the Construction Manager
shall have control over or charge of and shall be responsible for coordination
of the Contractor's construction means, methods, techniques, sequences or
procedures, and for safety precautions and programs by the Contractor in
connection with the Work of each of the Contractors. The Construction Manager
shall be responsible for a Contractor's failure to carry out the Work in
accordance with the respective Contract Documents. The Construction Manager
shall have control over or charge of acts or omissions of the Contractors,
Subcontractors, or their agents or employees, or any other persons performing
portions of the Work directly employed by the Construction Manager. The
aforementioned statement of control, charge and responsibility shall not
obligate the Construction Manager to assume any additional financial obligations
associated with the Work performed by the Contractors.Subcontractors, vendors,
agents or employees.

2.3.16   The Construction Manager shall transmit to the Architect requests for
interpretations of the meaning and intent of the Drawings and Specifications,
and assist in the resolution of questions that may arise.

(C)1992 - THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W.,
WASHINGTON, D.C. 20006-5292. AIA DOCUMENT B801/CMa - OWNER-CONSTRUCTION MANAGER
AGREEMENT - 1992 EDITION - AIA(R)- WARNING: Unlicensed photocopying violates
U.S. copyright laws and will subject the violator to legal prosecution. This
document was electronically produced with permission of the AIA and can be
reproduced in accordance with your license without violation until the date of
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below. User Document: b801 dev agr apr uyya -- 4/9/2003. AIA
License Number 1768076504, which expires on 10/30/2003.

                                                 Electronic Format B801/CMa-1992

                                                                               4
<PAGE>

2.3.17   The Construction Manager shall review requests for changes, assist in
negotiating Contractors' proposals, submit recommendations to the Architect and
Owner, and, if they are accepted, prepare Change Orders and Construction Change
Directives which incorporate the Architect's modifications to the Documents.

2.3.18   The Construction Manager shall assist the Architect in the review,
evaluation and documentation of Claims.

2.3.19   The Construction Manager shall receive certificates of insurance from
the Contractors and forward them to the Owner with a copy to the Architect.

2.3.20   In collaboration with the Architect, the Construction Manager shall
establish and implement procedures for expediting the processing and approval of
Shop Drawings, Product Data, Samples and other submittals. The Construction
Manager shall review all Shop Drawings, Product Data, Samples and other
submittals from the Contractors. The Construction Manager shall coordinate
submittals with information contained in related documents and transmit to the
Architect those which have been approved by the Construction Manager. The
Construction Manager's actions shall be taken with such reasonable promptness as
to cause no delay in the Work or in the activities of the Owner or Contractors.

2.3.21   The Construction Manager shall record the progress of the Project. The
Construction Manager shall submit written progress reports to the Owner and
Architect including information on each Contractor and each Contractor's Work,
as well as the entire Project, showing percentages of completion. The
Construction Manager shall keep a daily log containing a record of weather, each
Contractor's Work on the site, number of workers, identification of equipment,
Work accomplished, problems encountered, and other similar relevant data as the
Owner may require.

2.3.22   The Construction Manager shall maintain at the Project site for the
Owner one record copy of all Contracts, Drawings, Specifications, addenda,
Change Orders and other Modifications, in good order and marked currently to
record changes and selections made during construction, and in addition,
approved Shop Drawings, Product Data, Samples and similar required submittals.
The Construction Manager shall maintain records, in duplicate, of principal
building layout lines, elevations of the bottom of footings, floor levels and
key site elevations certified by a qualified surveyor or professional engineer.
The Construction Manager shall make all such records available to the Architect
and upon completion of the Project shall deliver them to the Owner.

2.3.23   The Construction Manager shall coordinate with Contractor(s) for the
delivery, storage, protection and security of Owner-purchased materials, systems
and equipment that are a part of the Project until such items are incorporated
into the Project.

2.3.24   With the Architect and the Owner's maintenance personnel, the
Construction Manager shall observe the Contractors' final testing and start-up
of utilities, operational systems and equipment.

2.3.25   When the Construction Manager considers each Contractor's Work or a
designated portion thereof substantially complete, the Construction Manager
shall, jointly with the Contractor, prepare for the Architect a list of
incomplete or unsatisfactory items and a schedule for their completion. The
Construction Manager shall assist the Architect in conducting inspections to
determine whether the Work or designated portion thereof is substantially
complete.

2.3.26   The Construction Manager shall coordinate the correction and completion
of the Work. Following issuance of a Certificate of Substantial Completion of
the Work or a designated portion thereof, the Construction Manager shall
evaluate the completion of the Work of the Contractors and make recommendations
to the Architect when Work is ready for final inspection. The Construction
Manager shall assist the Architect in conducting final inspections.

2.3.27   The Construction Manager shall secure and transmit to the Architect
warranties and similar submittals required by the Contract Documents for
delivery to the Owner and deliver all keys, manuals, record drawings and
maintenance stocks to the Owner. The Construction Manager shall forward to the
Architect a final Project Application for Payment upon compliance with the
requirements of the Contract Documents.

2.3.28   Duties, responsibilities and limitations of authority of the
Construction Manager as set forth in the Contract Documents shall not be
restricted, modified or extended without written consent of the Owner,
Construction Manager, Architect and Contractors. Consent shall not be
unreasonably withheld.

                                    ARTICLE 3
                               ADDITIONAL SERVICES

3.1      GENERAL

3.1.1    The services described in this Article 3 are not included in Basic
Services unless so identified in Article 14, and they shall be paid for by the
Owner as provided in this Agreement, in addition to the compensation for Basic
Services. The Optional Additional Services described under Paragraph 3.3 shall
only be provided if authorized or confirmed in writing by the Owner. If services
described under Contingent Additional Services in Paragraph 3.2 are required due
to circumstances beyond the Construction Manager's control, the Construction
Manager shall notify the Owner prior to commencing such services. If the Owner
deems that such services described under Paragraph 3.2 are not required, the
Owner shall give prompt written notice to the Construction Manager. If the Owner
indicates in writing that all or part of such Contingent Additional Services are
not required, the Construction Manager shall have no obligation to provide those
services.

3.2      CONTINGENT ADDITIONAL SERVICES

(C) 1992 - THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W.,
WASHINGTON, D.C. 20006-5292. AIA DOCUMENT B801/CMa - OWNER-CONSTRUCTION MANAGER
AGREEMENT - 1992 EDITION - AIA(R) - WARNING; Unlicensed photocopying violates
U.S. copyright laws and will subject the violator to legal prosecution. This
document was electronically produced with permission of the AIA and can be
reproduced in accordance with your license without violation until the date of
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below. User Document: b801 dev agr apr uyya - 4/9/2003. AIA
License Number 1768076504, which expires on 10/30/2003.

                                                 Electronic Format B801/CMa-1992

                                                                               5
<PAGE>

3.2.1    Providing services required because of significant changes in the
Project including, but not limited to, changes in size, quality, complexity or
the Owner's schedule.

3.2.2    Providing consultation concerning replacement of Work damaged by fire
or other cause during construction, and furnishing services required in
connection with the replacement of such Work.

3.2.3    Providing services made necessary by the termination or default of the
Architect or a Contractor, by major defects or deficiencies in the Work of a
Contractor, or by failure of performance of either the Owner or Contractor under
a Contract for Construction.

3.2.4    Providing services in evaluating an extensive number of claims
submitted by a Contractor or others in connection with the Work.

3.2.5    Providing services in connection with a public hearing, arbitration
proceeding or legal proceeding except where the Construction Manager is party
thereto.

3.3      OPTIONAL ADDITIONAL SERVICES

3.3.1    Providing services relative to future facilities, systems and
equipment.

3.3.2    Providing services to investigate existing conditions or facilities or
to provide measured drawings thereof.

3.3.3    Providing services to verify the accuracy of drawings or other
information furnished by the Owner.

3.3.4    Providing services required for or in connection with the Owner's
selection, procurement or installation of furniture, furnishings and related
equipment.

3.3.5    (included in Basic Services)

3.3.6    Providing any other services not otherwise included in this Agreement.

                                    ARTICLE 4
                            OWNER'S RESPONSIBILITIES

4.1      The Owner shall provide full information regarding requirements for the
Project, including a program which shall set forth the Owner's objectives,
schedule, constraints and criteria, including space requirements and
relationships, flexibility, expandability, special equipment, systems, and site
requirements.

4.2      The Owner shall establish and update an overall budget for the Project
based on consultation with the Construction Manager and Architect, which shall
include the Construction Cost, the Owner's other costs and reasonable
contingencies related to all of these costs.

4.3      If requested by the Construction Manager, the Owner shall furnish
evidence that financial arrangements have been made to fulfill the Owner's
obligations under this Agreement.

4.4      The Owner shall designate a representative authorized to act on the
Owner's behalf with respect to the Project. The Owner, or such authorized
representative, shall render decisions in a timely manner pertaining to
documents submitted by the Construction Manager in order to avoid unreasonable
delay in the orderly and sequential progress of the Construction Manager's
services.

4.5      The Owner shall retain an architect whose services, duties and
responsibilities are described in the edition of AIA Document B141/Cma, Standard
Form of Agreement Between Owner and Architect, Construction Manager-Adviser
Edition, current as of the date of this Agreement. The Terms and Conditions of
the Agreement Between the Owner and Architect shall be furnished to the
Construction Manager and shall not be modified without written consent of the
Construction Manager, which consent shall not be unreasonably withheld. The
Construction Manager shall not be responsible for actions taken by the
Architect.

4.6      The Owner shall furnish structural, mechanical, chemical, air and water
pollution tests, tests for hazardous materials, and other laboratory and
environmental tests, inspections and reports required by law or the Contract
Documents.

4.7      The Owner shall furnish all legal, accounting and insurance counseling
services as may be necessary at any time for the Project, including auditing
services the Owner may require to verify the Contractors' Applications for
Payment or to ascertain how or for what purposes the Contractors have used the
money paid by or on behalf of the Owner.

4.8      The Owner shall furnish the Construction Manager with a sufficient
quantity of Construction Documents.

4.9      The services, information and reports required by Paragraphs 4.5
through 4.8 shall be furnished at the Owner's expense, and the Construction
Manager shall be entitled to rely upon the accuracy and completeness thereof.

4.10     Prompt written notice shall be given by the Owner to the Construction
Manager and Architect if the Owner becomes aware of any fault or defect in the
Project or nonconformance with the Contract Documents.

4.11     The Owner reserves the right to perform construction and operations
related to the Project with the Owner's own forces, and to award contracts in
connection with the Project which are not part of the Construction Manager's
responsibilities under this Agreement. The Construction Manager shall notify the
Owner if any such independent action will interfere with the Construction
Manager's ability to perform the Construction Manager's responsibilities under
this Agreement. When performing construction or operations related to the
Project, the Owner agrees to be subject to the same obligations and to have the
same rights as the Contractors.

4.12     Information or services under the Owner's control shall be furnished by
the Owner with reasonable promptness to

(C)1992 - THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W.,
WASHINGTON, D.C. 20006-5292, AIA DOCUMENT B801/CMa - OWNER-CONSTRUCTION MANAGER
AGREEMENT - 1992 EDITION - AIA(R)- WARNING: Unlicensed photocopying violates
U.S. copyright laws and will subject the violator to legal prosecution. This
document was electronically produced with permission of the AIA and can be
reproduced in accordance with your license without violation until the date of
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below. User Document: b801 dev agr apr uyya - 4/9/2003. AIA
License Number 1768076504, which expires on 10/30/2003.

                                                 Electronic Format B801/CMa-1992

                                                                               6
<PAGE>

avoid delay in the orderly progress of the Construction Manager's services and
the progress of the Work.

                                    ARTICLE 5
                                CONSTRUCTION COST

5.1      DEFINITION

5.1.1    The Construction Cost shall be the total cost or estimated cost to the
Owner of all elements of the Project designed or specified by the Architect.

5.1.2    The Construction Cost shall include the cost at current market rates of
labor and materials furnished by the Owner and equipment designed, specified,
selected or specially provided for by the Architect, plus a reasonable allowance
for the Contractors' overhead and profit. In addition, a reasonable allowance
for contingencies shall be included for market conditions at the time of bidding
and for changes in the Work during construction. Except as provided in
Subparagraph 5.1.3, Construction Cost shall also include the compensation of the
Construction Manager and Construction Manager's consultants.

5.1.3    Construction Cost does not include the compensation of the Architect
and Architect's consultants, costs of the land, rights-of-way, financing or
other costs which are the responsibility of the Owner as provided in Article 4.
If any portion of the Construction Manager's compensation is based upon a
percentage of Construction Cost, then Construction Cost, for the purpose of
determining such portion, shall not include the compensation of the Construction
Manager or Construction Manager's consultants.

5.2      RESPONSIBILITY FOR CONSTRUCTION COST

5.2.1    Evaluations of the Owner's Project budget, preliminary estimates of
Construction Cost and detailed estimates of Construction Cost prepared by the
Construction Manager represent the Construction Manager's best judgment as a
person or entity familiar with the construction industry. It is recognized,
however, that neither the Construction Manager nor the Owner has control over
the cost of labor, materials or equipment, over Contractors' methods of
determining bid prices, or over competitive bidding, market or negotiating
conditions. Accordingly, the Construction Manager cannot and does not warrant or
represent that bids or negotiated prices will not vary from the Project budget
proposed, established or approved by the Owner, or from any cost estimate or
evaluation prepared by the Construction Manager.

5.2.2    No fixed limit of Construction Cost shall be established as a condition
of this Agreement by the furnishing, proposal or establishment of a Project
budget unless such fixed limit has been agreed upon in writing and signed by the
parties hereto. If such a fixed limit has been established, the Construction
Manager shall be permitted to include contingencies for design, bidding and
price escalation, and shall consult with the Architect to determine what
materials, equipment, component systems and types of construction are to be
included in the Contract Documents, to suggest reasonable adjustments in the
scope of the Project, and to suggest inclusion of alternate bids in the
Construction Documents to adjust the Construction Cost to the fixed limit. Fixed
limits, if any, shall be increased in the amount of any increase in the Contract
Sums occurring after execution of the Contracts for Construction.

5.2.3    If the Bidding or Negotiation Phase has not commenced within 90 days
after submittal of the Construction Documents to the Owner, any Project budget
or fixed limit of Construction Cost shall be adjusted to reflect changes in the
general level of prices in the construction industry between the date of
submission of the Construction Documents to the Owner and the date on which
proposals are sought.

5.2.4    If a fixed limit of Construction Cost (adjusted as provided in
Subparagraph 5.2.3) is exceeded by the sum of the lowest bona fide bids or
negotiated proposals plus the Construction Manager's estimate of other elements
of Construction Cost for the Project, the Owner shall:

         .1       give written approval of an increase in such fixed limit;

         .2       authorize rebidding or renegotiating of the Project within a
                  reasonable time;

         .3       if the Project is abandoned, terminate in accordance with
                  Paragraph 9.3; or

         .4       cooperate in revising the Project scope and quality as
                  required to reduce the Construction Cost.

5.2.5    If the Owner chooses to proceed under Clause 5.2.4.4, the Construction
Manager, without additional charge, shall cooperate with the Owner and Architect
as necessary to bring the Construction Cost within the fixed limit, if
established as a condition of this Agreement.

                                    ARTICLE 6
                         CONSTRUCTION SUPPORT ACTIVITIES

6.1      Construction support activities, if provided by the Construction
Manager, shall be governed by separate contractual agreements unless otherwise
provided in Article 14.

6.2      Reimbursable expenses listed in Article 14 for construction support
activities may be subject to trade discounts, rebates, refunds and amounts
received from sales of surplus materials and equipment which shall accrue to the
Owner, and the Construction Manager shall make provisions so that they can be
secured.

                                   ARTICLE 7
                              OWNERSHIP AND USE OF
                      ARCHITECT'S DRAWINGS, SPECIFICATIONS
                              AND OTHER DOCUMENTS

7.1      The Drawings, Specifications and other documents prepared by the
Architect are instruments of the Architect's service through which the Work to
be executed by the Contractors is described. The Construction Manager may retain

(C)1992 - THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W.,
WASHINGTON, D.C. 20006-5292. AIA DOCUMENT B801/CMa - OWNER-CONSTRUCTION MANAGER
AGREEMENT - 1992 EDITION - AIA(R)- WARNING: Unlicensed photocopying violates
U.S. copyright laws and will subject the violator to legal prosecution. This
document was electronically produced with permission of the AIA and can be
reproduced in accordance with your license without violation until the date of
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below. User Document: b801 dev agr apr uyya -- 4/9/2003. AIA
License Number 1768076504, which expires on 10/30/2003.

                                                 Electronic Format B801/CMa-1992

                                                                               7
<PAGE>

one record set. The Construction Manager shall not own or claim a copyright in
the Drawings, Specifications and other documents prepared by the Architect, and
unless otherwise indicated the Architect shall be deemed the author of them and
will retain all common law, statutory and other reserved rights, in addition to
the copyright. All copies of them, except the Construction Manager's record set,
shall be returned or suitably accounted for to the Architect, on request, upon
completion of the Project. The Drawings, Specifications and other documents
prepared by the Architect, and copies thereof furnished to the Construction
Manager, are for use solely with respect to this Project. They are not to be
used by the Construction Manager on other projects or for additions to this
Project outside the scope of the Work without the specific written consent of
the Owner and Architect. The Construction Manager is granted a limited license
to use and reproduce applicable portions of the Drawings, Specifications and
other documents prepared by the Architect appropriate to and for use in the
performance of the Construction Manager's services under this Agreement.

All copies made under this license shall bear the statutory copyright notice, if
any, shown on the Drawings, Specifications and other documents prepared by the
Architect. Submittal or distribution to meet official regulatory requirements or
for other purposes in connection with this Project is not to be construed as
publication in derogation of the Architect's copyright or other reserved rights.

                                    ARTICLE 8
                                   ARBITRATION

8.1      Claims, disputes or other matters in question between the parties to
this Agreement arising out of or relating to this Agreement or breach thereof
shall be subject to and decided by arbitration in accordance with the
Construction Industry Arbitration Rules of the American Arbitration Association
currently in effect unless the parties mutually agree otherwise.

8.2      Demand for arbitration shall be filed in writing with the other party
to this Agreement and with the American Arbitration Association. A demand for
arbitration shall be made within a reasonable time after the claim, dispute or
other matter in question has arisen. In no event shall the demand for
arbitration be made after the date when institution of legal or equitable
proceedings based on such claim, dispute or other matter in question would be
barred by the applicable statutes of limitations.

8.3      No arbitration arising out of or relating to this Agreement shall
include, by consolidation, joinder or in any other manner, an additional person
or entity not a party to this Agreement, except by written consent containing a
specific reference to this Agreement signed by the Owner, Construction Manager,
and any other person or entity sought to be joined. Consent to arbitration
involving an additional person or entity shall not constitute consent to
arbitration of any claim, dispute or other matter in question not described in
the written consent or with a person or entity not named or described therein.
The foregoing agreement to arbitrate and other agreements to arbitrate with an
additional person or entity duly consented to by the parties to this Agreement
shall be specifically enforceable in accordance with applicable law in any court
having jurisdiction thereof.

8.4      The award rendered by the arbitrator or arbitrators shall be final, and
judgment may be entered upon it in accordance with applicable law in any court
having jurisdiction thereof.

                                    ARTICLE 9
                     TERMINATION, SUSPENSION OR ABANDONMENT

9.1      This Agreement may be terminated by either party upon not less than
seven days' written notice should the other party fail substantially to perform
in accordance with the terms of this Agreement through no fault of the party
initiating the termination.

9.2      If the Project is suspended by the Owner for more than 30 consecutive
days, the Construction Manager shall be compensated for services performed prior
to notice of such suspension. When the Project is resumed, the Construction
Manager's compensation shall be equitably adjusted to provide for expenses
incurred in the interruption and resumption of the Construction Manager's
services.

9.3      This Agreement may be terminated by the Owner upon not less than seven
days' written notice to the Construction Manager in the event that the Project
is permanently abandoned. If the Project is abandoned by the Owner for more than
90 consecutive days, the Construction Manager may terminate this Agreement by
giving written notice.

9.4      Failure of the Owner to make payments to the Construction Manager in
accordance with this Agreement shall be considered substantial nonperformance
and cause for termination.

9.5      If the Owner fails to make payment when due the Construction Manager
for services and expenses, the Construction Manager may, upon seven days'
written notice to the Owner, suspend performance of services under this
Agreement. Unless payment in full is received by the Construction Manager within
seven days of the date of the notice, the suspension shall lake effect without
further notice. In the event of a suspension of services, the Construction
Manager shall have no liability to the Owner for delay or damage caused to the
Owner because of such suspension of services.

9.6      In the event of termination not the fault of the Construction Manager,
the Construction Manager shall be compensated for services performed prior to
termination, together with Reimbursable Expenses then due and all Termination
Expenses as defined in Paragraph 9.7.

9.7      Termination Expenses are those costs directly attributable to
termination for which the Construction Manager is not otherwise compensated.

                                   ARTICLE 10

(C)1992 - THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W.,
WASHINGTON, D.C. 20006-5292, AIA DOCUMENT B80l/CMa - OWNER-CONSTRUCTION MANAGER
AGREEMENT - 1992 EDITION - AIA(R)- WARNING: Unlicensed photocopying violates
U.S. copyright laws and will subject the violator to legal prosecution. This
document was electronically produced with permission of the AIA and can be
reproduced in accordance with your license without violation until the date of
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below. User Document: b801 dev agr apr uyya -- 4/9/2003. AIA
License Number 1768076504, which expires on 10/30/2003.

                                                 Electronic Format B801/CMa-1992

                                                                               8
<PAGE>

                            MISCELLANEOUS PROVISIONS

10.1     Unless otherwise provided, this Agreement shall be governed by the law
of the place where the Project is located.

10.2     Terms in this Agreement shall have the same meaning as those in the
modified version of the edition of AIA Document A201/CMa, General Conditions of
the Contract for Construction, Construction Manager-Adviser Edition, as agreed
upon between the Owner and Construction Manger.

10.3     Causes of action between the parties to this Agreement pertaining to
acts or failures to act shall be deemed to have accrued and the applicable
statutes of limitations shall commence to run not later than either the date of
Substantial Completion for acts or failures to act occurring prior to
Substantial Completion, or the date of issuance of the final Project Certificate
for Payment for acts or failures to act occurring after Substantial Completion.

10.4     Waivers of Subrogation. The Owner and Construction Manager waive all
rights against each other and against the Contractors, Architect, consultants,
agents and employees of any of them, for damages, but only to the extent covered
by property insurance during construction, except such rights as they may have
to the proceeds of such insurance as set forth in the edition of AIA Document
A201/CMa, General Conditions of the Contract for Construction, Construction
Manager-Adviser Edition, current as of the date of this Agreement. The Owner and
Construction Manager each shall require similar waivers from their Contractors,
Architect, consultants, agents, and persons or entities awarded separate
contracts administered under the Owner's own forces.

10.5     The Owner and Construction Manager, respectively, bind themselves,
their partners, successors, assigns and legal representatives to the other party
to this Agreement and to the partners, successors, assigns and legal
representatives of such other party with respect to all covenants of this
Agreement. Neither Owner nor Construction Manager shall assign this Agreement
without the written consent of the other.

10.6     This Agreement represents the entire and integrated agreement between
the Owner and Construction Manager and supersedes all prior negotiations,
representations or agreements, either written or oral. This Agreement may be
amended only by written instrument signed by both Owner and Construction
Manager.

10.7     Nothing contained in this Agreement shall create a contractual
relationship with or a cause of action in favor of a third party against either
the Owner or Construction Manager.

10.8     Unless otherwise provided in this Agreement, the Construction Manager
and the Construction Manager's consultants shall have no responsibility for the
discovery, presence, handling, removal or disposal of or exposure of persons to
hazardous materials in any form at the Project site, including but not limited
to asbestos, asbestos products, polychlorinated biphenyl (PCB) or other toxic
substances.

                                   ARTICLE 11
                                    INSURANCE

11.1     CONSTRUCTION MANAGER'S LIABILITY INSURANCE

11.1.1   The Construction Manager shall purchase from and maintain in a company
or companies lawfully authorized to do business in the jurisdiction in which the
Project is located such insurance as will protect the Construction Manager from
claims set forth below which may arise out of or result from the Construction
Manager's operations under this Agreement and for which the Construction Manager
may be legally liable.

         .1       claims under workers compensation, disability benefit and
                  other similar employee benefit acts which are applicable to
                  the operations to be performed;

         .2       claims for damages because of bodily injury, occupational
                  sickness or disease, or death of the Construction Manager's
                  employees;

         .3       claims for damages because of bodily injury, sickness or
                  disease, or death of any person other than the Construction
                  Manager's employees;

         .4       claims for damages insured by usual personal injury liability
                  coverage which are sustained (1) by a person as a result of an
                  offense directly or indirectly related to employment of such
                  person by the Construction Manager, or (2) by another person;

         .5       claims for damages, other than to the Work itself, because of
                  injury to or destruction of tangible property, including loss
                  of use resulting therefrom;

         .6       claims for damages because of bodily injury, death of a person
                  or property damage arising out of ownership, maintenance or
                  use of a motor vehicle.

11.1.2   The insurance required by Subparagraph 11.1.1 shall be written for not
less than limits of liability specified in Article 14 or required by law,
whichever coverage is greater. Coverages, whether written on an occurrence or
claims-made basis, shall be maintained without interruption from date of
commencement of operations under this Agreement until date of final payment and
termination of any coverage required to be maintained after final payment.

                                   ARTICLE 12
                      PAYMENTS TO THE CONSTRUCTION MANAGER

12.1     DIRECT PERSONNEL EXPENSE

12.1.1   Direct Personnel Expense is defined as the direct salaries of the
Construction Manager's personnel engaged on the Project and the portion of the
cost of their mandatory and customary contributions and benefits related
thereto, such as employment taxes and other statutory employee benefits,
insurance, sick leave, holidays, vacations, pensions and similar contributions
and benefits.

(C)1992 - THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W.,
WASHINGTON, D.C. 20006-5292. AIA DOCUMENT B801/CMa - OWNER-CONSTRUCTION MANAGER
AGREEMENT - 1992 EDITION - AIA(R)- WARNING: Unlicensed photocopying violates
U.S. copyright laws and will subject the violator to legal prosecution. This
document was electronically produced with permission of the AIA and can be
reproduced in accordance with your license without violation until the date of
expiration as noted below. expiration as noted below, expiration as noted below,
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below. User Document: b801 dev agr apr uyya - 4/9/2003. AIA
License Number 1768076504, which expires on 10/30/2003.

                                                 Electronic Format B801/CMa-1992

                                                                               9
<PAGE>

12.2     REIMBURSABLE EXPENSES

12.2.1   Reimbursable Expense are in addition to compensation for Basic and
Additional Services and include expenses incurred by the Construction Manager
and Construction Manager's employees and consultants in the interest of the
Project, as identified in the following Clauses.

12.2.1.1 Expense of transportation in connection with the Project, expenses in
connection with authorized out-of-town travel; long-distance communications; and
fees paid for securing approval of authorities having jurisdiction over the
Project.

12.2.1.2 Expense of reproductions, express deliveries, and handling of Drawings,
Specifications and other documents.

12.2.1.3 If authorized in advance by the Owner, expense of overtime work
requiring higher than regular rates.

12.2.1.4 Expense of additional insurance coverage or limits requested by the
Owner in excess of that normally carried by the Construction Manager.

12.3     PAYMENTS ON ACCOUNT OF BASIC SERVICES

12.3.1   An initial payment as set forth in Paragraph 13.1 is the minimum
payment under this Agreement.

12.3.2   Subsequent payments for Basic Services shall be made monthly and, where
applicable, shall be in proportion to services performed within each phase of
service, on the basis set forth in Subparagraph 13.2.1.

12.3.3   If and to the extent that the time initially established in
Subparagraph 13.5.1 of this Agreement is exceeded or extended through no fault
of the Construction Manager, compensation for any services rendered during the
additional period of time shall be computed in the manner set forth in
Subparagraph 13.3.1.

12.3.4   When compensation is based on a percentage of Construction Cost and any
portions of the Project are deleted or otherwise not constructed, compensation
for those portions of the Project shall be payable to the extent services are
performed on those portions, in accordance with Subparagraph 13,2.1, based on
(1) the lowest bona fide bids or negotiated proposals, or (2) if no such bids or
proposals are received, the latest approved estimate of such portions of the
Project.

12.4     PAYMENTS ON ACCOUNT OF ADDITIONAL SERVICES AND REIMBURSABLE EXPENSES

12.4.1   Payments on account of the Construction Manager's Additional Services
and for Reimbursable Expenses shall be made monthly upon presentation of the
Construction Manager's statement of services rendered or expenses incurred.

12.5     PAYMENTS WITHHELD

12.5.1   No deductions shall be made from the Construction Manager's
compensation on account of penalty, liquidated damages or other sums withheld
from payments to Contractors, or on account of the cost of changes in Work other
than those for which the Construction Manager has been found to be liable.

12.6     CONSTRUCTION MANAGER'S ACCOUNTING RECORDS

12.6.1   Records of Reimbursable Expenses and expenses pertaining to Additional
Services and services performed on the basis of a multiple of Direct Personnel
Expense shall be available to the Owner or the Owner's authorized representative
at mutually convenient times.

                                   ARTICLE 13
                              BASIS OF COMPENSATION

The Owner shall compensate the Construction Manager as follows:

13.1     AN INITIAL PAYMENT of zero Dollars ($ -0- ) shall be made upon
execution of this Agreement and credited to the owner's account at final
payment.

13.2     BASIC COMPENSATION

13.2.1   FOR BASIC SERVICES, as described in Article 2, and any other services
included in Article 14 as part of Basic Services, Basic Compensation shall be
computed as follows:

For Pre-Construction Phase Services:

(Insert basis of compensation, including stipulated sums, multiples or
percentages.)

Fifteen thousand dollars ($15,000) per month.

Project organization, mobilization, consultant selection, design review
(estimated at 3 to 4 months) @ $15,000 per month.

For Construction Phase Services:

(Insert basis of compensation, including stipulated sums, multiples or
percentages.)

(C) 1992 - THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W.,
WASHINGTON, D.C. 20006-5292. AIA DOCUMENT B801/CMa - OWNER-CONSTRUCTION MANAGER
AGREEMENT - 1992 EDITION - AIA(R) - WARNING: Unlicensed photocopying violates
U.S. copyright laws and will subject the violator to legal prosecution. This
document was electronically produced with permission of the AIA and can be
reproduced in accordance with your license without violation until the date of
expiration as noted below. expiration as noted below, expiration as noted below,
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below. User Document: b801 dev agr apr uyya -- 4/9/2003. AIA
License Number 1768076504, which expires on 10/30/2003.

                                                 Electronic Format B801/CMa-1992

                                                                              10
<PAGE>

Twenty thousand dollars ($20.000) per month.

Management during construction (estimated at 12 months) @ $20,000 per month.

13.3     COMPENSATION FOR ADDITIONAL SERVICES

13.3.1   FOR ADDITIONAL SERVICES OF THE CONSTRUCTION MANAGER, as described in
Article 3, and any other services included in Article 14 as Additional Services,
compensation shall be computed as follows:

(Insert basis of compensation, including rates and/or multiples of Direct
Personnel Expense for Principals and employees, and identify Principals and
classify employees, if required. Identify specific services to which particular
methods of compensation apply, if necessary.)

Additional services shall be mutually agreed to by Owner and Construction
Manager.

The following rates for Construction Manager's key personnel shall apply:

Rick Heymann - $200 per day
Mike Rosamond - $300 per day
Murray Newton - $350 per day

13.4     REIMBURSABLE EXPENSES

13.4.1   FOR REIMBURSABLE EXPENSES, as described in Paragraph 12.2, and any
other items included in Article 14 as Reimbursable Expenses, a multiple of one (
1.0 ) times the expenses incurred by the Construction Manager and the
Construction Manager's employees and consultants in the interest of the Project.

13.5     ADDITIONAL PROVISIONS

13.5.1   IF THE BASIC SERVICES covered by this Agreement have not been completed
within Sixteen (16 ) months of the date hereof, through no fault of the
Construction Manager, extension of the Construction Manager's services beyond
that time shall be compensated as provided in Subparagraphs 12.3.3 and 13.3.1.

13.5.2   Payments are due and payable twenty ( 20 ) days from the date of the
Construction Manager's invoice. Amounts unpaid twenty ( 20 ) days after the
invoice date shall bear interest at the rate entered below, or in the absence
thereof at the legal rate prevailing from time to time at the principal place of
business of the Construction Manager.

(Insert rate of interest agreed upon.)

(Usury laws and requirements under the Federal Truth in Lending Act, similar
state and local consumer credit laws and other regulations at the Owner's and
Construction Manager's principal places of business, the location of the Project
and elsewhere may affect the validity of this provision. Specific legal advice
should he obtained with respect to deletions or modifications, and also
regarding requirements such as written disclosures or waivers.)

13.5.3   The rales and multiples set forth for Additional Services shall be
annually adjusted in accordance with normal salary review practices of the
Construction Manager.

                                   ARTICLE 14
                          OTHER CONDITIONS OR SERVICES

(Insert descriptions of other services, identify Additional Services included
within Basic Compensation and modifications to the payment and compensation
terms included in this Agreement.)

The following exhibits to this Agreement shall apply:

Exhibit A- CM Services Responsibility Matrix

14.1     LIMITS ON INSURANCE

The insurance required by Article II shall be written for not less than the
following limits, or greater if required by law:

(Insert the specific dollar amounts for the appropriate insurance limits of
liability.)

14.1.1   Worker's Compensation:

         14.1.1.1 Minimum Limits:

                  (a)      Worker's Compensation - statutory limit

                  (b)      Employer's Liability:

                           (i)      $1,000,000 bodily injury for each accident

(C)1992 - THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W.,
WASHINGTON, D.C. 20006-5292. AIA DOCUMENT B801/CMa - OWNER-CONSTRUCTION MANAGER
AGREEMENT - 1992 EDITION - AIA(R)- WARNING: Unlicensed photocopying violates
U.S. copyright laws and will subject the violator to legal prosecution. This
document was electronically produced with permission of the AIA and can be
reproduced in accordance with your license without violation until the date of
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below. User Document: b801 dev agr apr uyya -- 4/9/2003. AIA
License Number 1768076504, which expires on 10/30/2003.

                                                 Electronic Format B801/CMa-1992

                                                                              11
<PAGE>

                           (ii)     $1,000,000 bodily injury by disease for each
                                    employee

                           (iii)    $1,000,000 bodily injury disease aggregate

14.1.2   Commercial General Liability:

         14.1.2.1 Minimum Limits:

                  (a)      $1,000,000 each occurrence

                  (b)      $2,000,000 general aggregate

                  (c)      $2,000,000 products and completed operations
                           aggregate

         14.1.2.2 Coverages:

                  (a)      Products and completed operations coverage

                  (b)      Blanket contractual liability

                  (c)      Broad form property coverage

                  (d)      Severability of interest

                  (e)      Personal injury

                  (f)      Specific waiver of subrogation

14.1.3   Automobile Liability:

         14.1.3.1 Minimum Limits: $1.000.000 combined single limit each accident

         14.1.3.2 Coverages:

                  (a)      Additional insured endorsement

                  (b)      Specific waiver of subrogation

                  (c)      Contractual liability

14.1.4   Umbrella / Excess Liability:

         14.1.4.1 Minimum Limits: $25,000,000 combined single limit and
                  aggregate limit

This Agreement entered into as of the day and year first written above.

OWNER                                              CONSTRUCTION MANAGER

/s/ F. Robert Merrill                            /s/ Murray Newton
----------------------------------               -------------------------------
(Signature)                                      (Signature)

F. ROBERT MERRILL, EXECUTIVE                     MURRAY NEWTON, EXECUTIVE VICE
VICE PRESIDENT, CFO                              PRESIDENT
(Printed name and title)                          (Printed name and title)

(c) 1992 - THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W.,
WASHINGTON, D.C. 20006-5292. AIA DOCUMENT B801/CMa - OWNER-CONSTRUCTION MANAGER
AGREEMENT - 1992 EDITION - AIA(R)- WARNING: Unlicensed photocopying violates
U.S. copyright laws and will subject the violator to legal prosecution. This
document was electronically produced with permission of the AIA and can be
reproduced in accordance with your license without violation until the date of
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below, expiration as noted below, expiration as noted below,
expiration as noted below. User Document: b801 dev agr apr 8.aia - 4/9/2003. AIA
License Number 1005237, which expires on 10/30/2003.

                                                 Electronic Format B801/CMa-1992

                                                                              12

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00062-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00062-of-00352.parquet"}]]