Document:

Exhibit 10.19

    Exhibit
      10.19

    

    AGREEMENT

    

    made
      as
      of the Twenty-ninth (29th) day of July, 2007

    

    BETWEEN
      the Owner:

    Promotora
      Valle Hermosa, Inc.

    1809
      E.
      Broadway St., Ste 346

    Oviedo,
      Florida 32765

    

    and
      the
      Architect:

    (Name
      and
      address)

    JNP
      Architectos, Inc.

    Ave
      America 4641 y Manosca

    Quito
      Ecuador

    

    For
      the
      Development Projects undertaken by Promotora Valle Hermosa within the next
      two
      years after the date on the present contract.

    

    The
      Owner
      and Architect agree as set forth below.

    

    TERMS
      AND
      CONDITIONS OF AGREEMENT BETWEEN OWNER AND ARCHITECT

     

    ARTICLE
      1

    

    ARCHITECT'S
      RESPONSIBILITIES

    

    1.1
      ARCHITECT'S SERVICES

    

    1.1.1
      The
      Architect's services consist of those services performed by the Architect,
      Architect's employees and Architect's consultants as enumerated in Articles
      2
      and 3 of this Agreement and any other services included in Article
      12.

    

    1.1.2
      The
      Architect's services shall be performed as expeditiously as is consistent with
      professional skill and care and the orderly progress of the Work. Upon request
      of the owner, the Architect shall submit for the Owner's approval a schedule
      for
      the performance of the Architect's services which may be adjusted as the Project
      proceeds, and shall include allowances for periods of time required for the
      Owner's review and for approval of submissions by authorities having
      jurisdiction over the Project. Time limits established by this schedule approved
      by the owner shall not, except for reasonable cause, be exceeded by the
      Architect or Owner.

    

    1.1.3
      The
      services covered by this Agreement are subject to the time limitations contained
      in Subparagraph 11.5.1.

    

    ARTICLE
      2

    

    SCOPE
      OF
      ARCHITECT'S BASIC SERVICES

    

    2.1
      DEFINITION

    

    2.1.1
      The
      Architect's Basic Services consist of those described in Paragraphs 2.2 through
      2.6 and any other services identified in Article 12 as part of Basic Services,
      and include normal structural, mechanical and electrical engineering
      services.

    

    2.2
      SCHEMATIC DESIGN PHASE

    

    2.2.1
      The
      Architect shall review the program furnished by the Owner to ascertain the
      requirements of the Project and shall arrive at a mutual understanding of such
      requirements with the Owner.

    
      
        
        

      

      
        
        

        
          

        

      

      
        
        

      

    

    2.2.2
      The
      Architect shall provide a preliminary evaluation of the Owner's program,
      schedule and construction budget requirements, each in terms of the other,
      subject to the limitations set forth in the present agreement.

    

    2.2.3
      The
      Architect shall review with the Owner alternative approaches to design and
      construction of the Project.

    

    2.2.4
      Based on the mutually agreed-upon program, schedule and construction budget
      requirements, the Architect shall prepare, for approval by the Owner, Schematic
      Design Documents consisting of drawings and other documents illustrating the
      scale and relationship of Project components.

    

    2.2.5
      The
      Architect shall submit to the Owner a preliminary estimate of Construction
      Cost
      based on current area, blouse or other unit costs.

    

    2.3
      DESIGN DEVELOPMENT PHASE

    

    2.3.1
      Based on the approved Schematic Design Documents and any adjustments authorized
      by the Owner in the program, schedule or construction budget, the Architect
      shall prepare, for approval by the Owner, Design Development Documents
      consisting of drawings and other documents to fix and describe the size and
      character of the Project as to architectural, structural, mechanical and
      electrical systems, materials and such other elements as may be
      appropriate.

    

    2.3.2
      The
      Architect shall advise the Owner of any adjustments to the preliminary estimate
      of Construction Cost.

    

    2.4
      CONSTRUCTION DOCUMENTS PHASE

    

    2.4.1
      Based on the approved Design Development Documents and any further adjustments
      in the scope or quality of the Project of in the construction budget authorized
      by the Owner, the Architect shall prepare, for approval by the Owner,
      Construction Documents consisting of Drawings and Specifications setting forth
      in detail the requirements for the construction of the Project.

    

    2.4.2
      The
      Architect shall assist the Owner in the preparation of the necessary bidding
      information, bidding forms, the Conditions of the Contract, and the form of
      Agreement between the Owner and Contractor.

    

    2.4.3
      The
      Architect shall advise the Owner of any adjustments to previous preliminary
      estimates of Construction Cost indicated by changes in requirements or general
      market conditions.

    

    2.4.4
      The
      Architect shall assist the Owner in connection with the Owner's responsibility
      for filing documents required for the approval of governmental authorities
      having jurisdiction over the Project.

    

    2.5.1
      The
      Architect shall review and approve or take other appropriate action upon all
      Contractor's submittals such as Shop Drawings, Product Data and Samples, but
      only for the limited purpose of checking for conformance with information given
      and the design concept expressed in the Contract Documents. The Architect's
      action shall be taken with such reasonable

    promptness
      as to cause no delay in the Work or in the construction of the Owner or of
      separate contractors, while allowing sufficient time in the Architect's
      professional judgment to permit adequate review. Review of such submittals
      is
      not conducted for the purpose of determining the accuracy and completeness
      of
      other details such as dimensions and quantities or for

    substantiating
      instructions for installation or performance of equipment or systems designed
      by
      the Contractor, all of which remain the responsibility of the Contractor, to
      the
      extent required by the Contract Documents. The Architect's review shall not
      constitute approval of safety precautions or, unless otherwise specifically
      stated by the Architect, of construction means,

    methods,
      techniques, sequences or procedures. The Architect's approval of a specific
      item
      shall not indicate approval of an assembly of which the item is a component.
      When professional certification of performance characteristics of materials,
      systems or equipment is required by the Contract Documents, the Architect shall
      be entitled to rely upon such certification to establish that the materials,
      systems or equipment will meet the performance criteria required by the Contract
      Documents.

    
      
        
        

      

      
        
        

        
          

        

      

      
        
        

      

    

    2.5.2
      The
      Architect shall prepare Change Orders and Construction Change Directives, with
      supporting documentation and data if deemed necessary by the Architect as
      provided in the present agreement, for the Owner's approval and execution in
      accordance with the Contract Documents, and may authorize minor changes in
      the
      Work not involving an adjustment in the Contract Sum or an extension of the
      Contract Time which are not inconsistent with the intent of the Contract
      Documents and or the intended functional use of the Facilities.

    

    2.5.3
      The
      Architect shall interpret and decide matters concerning performance of the
      Owner
      and Contractor under the requirements of the Contract Documents on written
      request of either the Owner or Contractor. The Architect's response to such
      requests shall be made with reasonable promptness and within any time limits
      agreed upon.

    

    2.5.4
      Interpretations and decisions of the Architect shall be consistent with the
      intent of and reasonably inferable from the Contract Documents and shall be
      in
      writing or in the form of drawings. When making such interpretations and initial
      decisions, the Architect shall endeavor to

    secure
      faithful performance by both Owner and Contractor, shall not show partiality
      to
      either, and shall not be liable for results of interpretations or decisions
      so
      rendered in good faith.

    

    2.5.5
      The
      Architect's decisions on matters relating to aesthetic effect shall be final
      if
      consistent with the intent expressed in the Contract Documents.

    

    2.5.6
      The
      Architect shall render written decisions within a reasonable time on all claims,
      disputes or other matters in question between the Owner and Contractor relating
      to the execution or progress of the Work as provided in the Contract
      Documents.

    

    ARTICLE
      3

    ---------

    ADDITIONAL
      SERVICES

    

    3.1
      GENERAL

    

    3.1.1
      The
      services described in this Article 3 are not included in Basic Services unless
      so identified in Article 12, and they shall be paid for by the Owner as provided
      in this Agreement, in addition to the compensation for Basic Services. The
      services shall only be provided if authorized or confirmed in writing by the
      Owner. If services described under Contingent Additional Services are required
      due to circumstances beyond the Architect's control, the Architect shall notify
      the Owner prior to commencing such services. If the Owner deems that such
      services described in the present agreement are not required, the Owner shall
      give prompt written notice to the Architect. If the Owner indicates in writing
      that all or part of such contingent Additional Services are not required, the
      Architect shall have no obligation to provide those services.

    

    ARTICLE
      3

    ----------

    OWNER'S
      RESPONSIBILITIES

    

    3.1
      The
      Owner shall provide full information regarding requirements for the Project,
      including a program which shall set forth the Owner's objectives, schedule,
      constraints and criteria, including space requirements and relationships,
      flexibility, expandability, special equipment, systems and site
      requirements.

    

    3.2
      The
      Owner shall establish and update an overall budget for the Project, including
      the Construction Cost, the Owner's other costs and reasonable contingencies
      related to all of these costs.

    

    3.3
      If
      requested by the Architect, the Owner shall furnish evidence that financial
      arrangements have been made to fulfill the Owner's obligations under this
      Agreement.

    

    3.4
      The
      Owner shall designate a representative authorized to act on the Owner's behalf
      with respect to the Project. The Owner or such authorized representative shall
      render decisions in a timely manner pertaining to documents submitted by the
      Architect in order to avoid unreasonable delay in the orderly and sequential
      progress of the Architect's services.

    
      
        
        

      

      
        
        

        
          

        

      

      
        
        

      

    

    3.5
      The
      Owner shall furnish surveys describing physical characteristics, legal
      limitations and utility locations for the site of the Project, and a written
      legal description of the site. The surveys and legal information shall include,
      as applicable, grades and lines of streets, alleys, pavements and adjoining
      property and structures; adjacent drainage, rights-of-way, restrictions,
      easements, encroachments, zoning, deed restrictions, boundaries and contours
      of
      the site; locations, dimensions and necessary data pertaining to existing
      buildings, other improvements and trees; and information concerning available
      utility services and lines, both public and private, above and below grade,
      including inverts and depths. All the information on the survey shall be
      referenced to a project benchmark.

    

    3.6
      The
      Owner shall furnish the services of geotechnical engineers when 
      such
      services are requested by the Architect. Such services may include but are
      not
      limited to test borings, test pits, determinations of soil bearing values,
      percolation tests, evaluations of hazardous materials,

    ground
      corrosion and resistivity tests, including necessary operations for anticipating
      subsoil conditions, with reports and appropriate professional
      recommendations.

    

    3.6.1
      The
      Owner shall furnish the services of other consultants when such services are
      reasonable required by the scope of the Project and are requested by the
      Architect.

    

    3.7
      The
      Owner shall furnish structural, mechanical, chemical, air and water pollution
      tests, tests for hazardous materials, and other laboratory and environmental
      tests, inspections and reports required by law or the Contract
      Documents.

    

    3.7.1
      The
      Owner shall furnish an Environmental Assessment of the site when such tests
      are
      reasonable required by the Scope of the Project and are requested by the
      Architect.

    

    3.8
      The
      Owner shall furnish all legal, accounting and insurance counseling services
      as
      may be necessary at any time for the Project, including auditing services the
      Owner may require to verify the Contractor's Applications for Payment or to
      ascertain how or for what purposes the Contractor has used the money paid by
      or
      on behalf of the Owner.

    

    3.9
      The
      services, information, surveys and reports required by Paragraphs 3.5 through
      3.8 shall be furnished at the Owner's expense, and the Architect shall be
      entitled to rely upon the accuracy and completeness thereof.

    

    3.10
      Prompt written notice shall be given by the Owner to the Architect if the Owner
      becomes aware of any fault or defect in the Project or nonconformance with
      the
      Contract Documents.

    

    3.11
      The
      proposed language of certificates or certifications requested of the Architect
      or Architect's consultants shall be submitted to the Architect for review and
      approval at least 14 days prior to execution. The Owner shall not request
      certifications that would require knowledge or services beyond the scope of
      the
      Agreement.

    

    ARTICLE
      4

    --------- 

    CONTRUCTION
      COST

    

    4.1
      DEFINITION

    

    4.1.1
      The
      Construction Cost shall be the total cost or estimated cost to the owner of
      all
      elements of the Project designed or specified by the Architect.

    

    4.1.2
      The
      Construction Cost shall include the cost at current market rates of labor and
      materials furnished by the Owner and equipment designed, specified, selected
      or
      specially provided for by the Architect, plus a reasonable allowance for the
      Contractor's overhead and profit. In addition, a reasonable allowance for
      contingencies shall be included for market conditions at the time of bidding
      and
      for changes in the Work during construction.

    

    4.1.3
      Construction Cost does not include the compensation of the Architect and
      Architect's consultants, the costs of the land, rights-of-way, financing or
      other costs which are the responsibility of the Owner as provided in Article
      4.

    

    
      
        
        

      

      
        
        

        
          

        

      

      
        
        

      

    

    4.2
      RESPONSIBILITY FOR CONSTRUCTION COST

    

    4.2.1
      Evaluations of the Owner's Project budget, preliminary estimates of Construction
      Cost and detailed estimates of Construction Cost, if any, prepared by the
      Architect, represent the Architect's best judgment as a design professional
      familiar with the construction industry. It is

    recognized,
      however, that neither the Architect nor the Owner has control over the cost
      of
      labor, materials or equipment, over the Contractor's methods of determining
      bid
      prices, or over competitive bidding, market or negotiating conditions.
      Accordingly, the Architect cannot and does not warrant or represent that bids
      or
      negotiated prices will not vary from the Owner's Project budget or from any
      estimate of Construction Cost or evaluation prepared or agreed to by the
      Architect.

    

    4.2.2
      No
      fixed limit of Construction Cost shall be established as a condition of this
      Agreement by the furnishing, proposal or establishment of a Project budget,
      unless it regards the Architect fees or such fixed limit has been agreed upon
      in
      writing and signed by the parties hereto. If such a fixed limit has been
      established, the Architect shall be permitted to include contingencies for
      design, bidding and price escalation, to determine what materials, equipment,
      component systems and types of construction are to be included in the Contract
      Documents, to make reasonable adjustments in the scope of the Project and to
      include in the Contract Documents alternate bids to adjust the Construction
      Cost
      to the fixed limit. Fixed limits, if any, shall be increased in the amount
      of an
      increase in the Contract Sum occurring after execution of the Contract for
      Construction.

    

    4.2.3
      If
      the Bidding or Negotiation Phase has not commenced within 90 days after the
      Architect submits the Construction Documents to the Owner, any Project budget
      or
      fixed limit of Construction Cost shall be adjusted to reflect changes in the
      general level of prices in the construction industry between the date of
      submission of the Construction Documents to the Owner and the date on which
      proposals are sought.

    

    4.2.4
      If
      a fixed limit of Construction Cost (adjusted as provided in Subparagraph 4.2.3)
      is exceeded by the lowest bona fide bid or negotiated proposal, the Owner
      shall:

    

    .1
      give
      written approval of an increase in such fixed limit;

    

    .2
      authorize rebidding or renegotiating of the Project within a reasonable
      time;

    

    .3
      if the
      Project is abandoned, terminate in accordance with present agreement;
      or

    

    .4
      cooperate in revising the Project scope and quality as required to reduce the
      Construction Cost.

    

    4.2.4
      If
      the Owner chooses to proceed under Clause 4.2.4.4, the Architect, without
      additional charge, shall modify the Contract Documents as necessary to comply
      with the fixed limit, if established as a condition of this Agreement. The
      modification of Contract Documents shall be the limit of the Architect's
      responsibility arising out of the establishment of a fixed limit. The Architect
      shall be entitled to compensation in accordance with this Agreement for all
      services performed whether or not the Construction Phase is
      commenced.

    

    ARTICLE
      5

    ---------

    USE
      OF
      ARCHITECT'S DRAWINGS SPECIFICATIONS AND OTHER DOCUMENTS

    

    5.1
      The
      Drawings, Specifications and other documents prepared by the Architect for
      this
      Project are instruments of the Architect's service for use solely with respect
      to this Project and, unless otherwise provided, the Architect shall be deemed
      the author of these documents and shall retain all common law, statutory and
      other reserved rights, including the copyright. The Owner shall be permitted
      to
      retain copies, including reproducible copies, of the Architect's Drawings,
      Specifications and other documents shall not be used by the Owner or others
      on
      other projects, for additions to this Project or for completion of this Project
      by others, unless the Architect is adjudged to be in default under this
      Agreement, except by agreement in writing and with appropriate compensation
      to
      the Architect.

    

    5.2
      Submission or distribution of documents to meet official regulatory requirements
      or for similar purposes in connection with the Project is not to be construed
      as
      publication in derogation of the Architect's reserved rights.

    
      
        
        

      

      
        
        

        
          

        

      

      
        
        

      

    

    ARTICLE
      6

    ---------

    ARBITRATION

    

    6.1
      Unresolved claims, disputes and other matters in question between the parties
      to
      this Agreement arising out of or relating to this Agreement or breach thereof,
      shall be subject to lawful recourse of the parties pursuant to law in the
      Republic of Ecuador

    

    ARTICLE
      7

    ---------

    TERMINATION,
      SUSPENSION OR ABANDONMENT

    

    7.1
      This
      Agreement may be terminated by either party upon not less than seven days'
      written notice should the other party fail substantially to perform in
      accordance with the terms of this Agreement through no fault of the party
      initiating the termination.

    

    7.2
      If
      the Project is suspended by the Owner for more than 30 consecutive days, the
      Architect shall be compensated for services performed prior to notice of such
      suspension. When the Project is resumed, the Architect's compensation shall
      be
      equitably adjusted to provide for expenses incurred in the interruption and
      resumption of the Architect's services. However, such equitable adjustment
      to
      the Architect's compensation shall be paid only in those instances in which
      the
      Owner has not extended the period of time for the Architect's performance of
      services under this Agreement equal to the time by which the Project was
      suspended.

    

    7.3
      This
      Agreement may be terminated by the Owner upon not less than seven days' written
      notice to the architect in the event that the Project is permanently
      abandoned.

    

    7.4
      Failure of the Owner to make payments to the Architect in accordance with this
      Agreement shall be considered substantial nonperformance and cause for
      termination.

    

    7.5
      If
      the Owner fails to make payment when due the Architect for services and
      expenses, the Architect may, upon seven days' written notice to the Owner,
      suspend performance of services under this Agreement. Unless payment in full
      is
      received by the Architect within seven days of the date of the notice, the
      suspension shall take effect without further notice. In the event of a
      suspension of services, the Architect shall have no liability to the Owner
      for
      delay or damage caused the Owner because of such suspension of
      services.

    

    7.6
      In
      the event of termination not the fault of the Architect, the Architect shall
      be
      compensated for services performed prior to termination, together with
      Reimbursable Expenses then due.

    

    ARTICLE
      8

    -----------

    PAYMENTS
      TO THE ARCHITECT

    

    8.1
      DIRECT PERSONNEL EXPENSE

    

    8.1.1
      Direct Personnel Expense is defined as the direct salaries of the

    Architect's
      personnel engaged on the Project. Such Expense shall be established as a fixed
      fee for the duration of this contract at $150,000 cash or 250,000 shares S-8
      of
      the company (the company should decide to register S-8 stock in lieu of payment
      to the Architect at its sole discretion). 

    

    8.1.2
      If
      paid in stock, the whole amount should be prepaid before the Architect begins
      services. 

    

    8.2
      REIMBURSABLE EXPENSES

    

    8.2.1
      Reimbursable Expenses are in addition to compensation for Basic and Additional
      Services and include expenses incurred by the Architect and Architect's
      employees and consultants in the interest of the Project, as identified in
      the
      following Clauses.

    
      
        
        

      

      
        
        

        
          

        

      

      
        
        

      

    

    8.2.1.1
      Expense of transportation in connection with authorized out-of- town travel;
      long-distance communications; and fees paid for securing approval of authorities
      having jurisdiction over the Project.

    

    8.2.1.2
      Expense of reproductions, postage and handling of Drawings, Specifications
      and
      other documents.

    

    8.2.1.3
      If authorized in advance by the Owner, expense of overtime works requiring
      higher than regular rates.

    

    8.2.1.4
      Expense of renderings, models and mock-ups requested by the Owner.

    

    8.2.1.4
      Expense of additional insurance coverage or limits, including professional
      liability insurance, requested by the Architect and Architect's
      consultants.

    

    

    

    

    

    OWNER:
      Promotora Valle Hermoso, Inc.     ARCHITECT: JNP
      Arhitectos, Inc.

    

    By:
      /s/
      Ramon Rosales                  By:
/s/
      Jorge Narvaez 

    

    NAME:
      Ramon Rosales                NAME:
      Jorge
      Narvaez

    TITLE:
      President and CEO              
TITLE:
      PresidentExhibit 10.20

    Exhibit
      10.20

    

    CONSULTING
      AGREEMENT

    

    

    This
      consulting agreement (this “Agreement”) is made the 25th
      day of
      July 2001 by and between Promotora Valle Hermosa Corporation, (the “Company”),
      and Margarita Romero, on (the “Consultant”).

    

    RECITALS

    

    WHEREAS,
      the Company wishes to engage the Consultant with respect to certain aspects
      of
      its business;

    

    WHEREAS,
      the Consultant is willing to make available to the Company the consulting
      services provided for in the Agreement as set forth below;

    

    AGREEMENT

    

    NOW
      THEREFORE, in consideration of the premises and the respective covenants and
      agreements of the parties herein contained, the parties hereto agree as
      follows:

    

    1.
      TERM

    

    The
      term
      of this Agreement shall commence on the date hereof and end on August 5,
      2008.

    

    2.
      CONSULTING SERVICES

    

    (a)
      Long
      range corporate and legal consulting and business development, including but
      not
      limited to the development of corporate strategy, market direction and
      implantation of business plans; Review and analysis of potential land purchase
      offers, construction developments offers and customers issues.

    (b)
      Compensation. In consideration of the consulting services set forth in paragraph
      2 (a), and subject to the terms and conditions set forth herein the Company
      hereby agrees to issue to Consultant 100,000 restricted shares of the Company’s
      Common stock (the “Shares”) with Piggy Back Registration rights and 50,000
      shares of the Company’s Common stock (the “Shares”) and register such shares at
      the time of initial issuance, or immediately thereafter, on Form S-8 under
      the
      Securities Act of 1933.

    (c)
      Issuance. Issuance and delivery of the Common Stock shall be within 45 days
      of
      the full reporting date of the company, at which time, the Company shall deliver
      to the Consultant:

    (i)
      the
      certificate or certificates evidencing the Shares to be issued to the Consultant
      and the respective dates, registered in the name of the Consultant; and
      (ii)evidence that the Shares have been registered on Form S-8 to be filed upon
      issuance of the Shares to the Consultant, registering for resale
      thereof.

    (d)
      Expenses.

    During
      the term of the Consultant’s engagement hereunder. The Consultant shall be
      entitled to receive prompt reimbursement for all reasonable expenses incurred
      by
      the Consultant in performing services hereunder, including all travel and living
      expenses while away from home on business at the request of and in the service
      of the Company, provided that such expenses are incurred and accounted for
      in
      accordance with the policies and procedures established by the Company, and
      that
      any expenses in excess of $100.00 have been pre-approved in writing by the
      Company.

    
      
        
        

      

      
        
        

        
          

        

      

      
        
        

      

    

    3.
      CONFIDENTIAL INFORMATION

    

    (a)
      Confidential Information. In connection with the providing of Consulting
      Services, hereunder, the Company may provide the Consultant with information
      concerning the Company which the Company deems confidential (the “Confidential
      Information”). The Consultant understands and agrees that any Confidential
      Information disclosed pursuant to this Agreement is secret, proprietary and
      of
      great value to the Company, which value may be impaired if the secrecy of such
      information is not maintained. The Consultant further agrees that he will take
      reasonable security measures to preserve and protect the secrecy of such
      Confidential Information, and to hold such information in confidence and not
      to
      disclose such information, either directly or indirectly to any person or entity
      during the term of this agreement or any time following the expiration or
      termination hereof; provided, however, that the Consultant may disclose the
      Confidential Information to an assistant to whom disclosure isnecessary for
      the
      providing of services under this agreement. 

    (b)
      Exclusions. For purposes of this paragraph 3, the term Confidential Information
      shall not include Information which (i) becomes generally available to the
      public other than as a result of a disclosure by the Consultant or his
      assistants, agents or advisors, or (ii) becomes available on a non-confidential
      basis to the Consultant from a source other than the Company or it’s
      advisors,

    provided
      that such source is not known to the Consultant to be bound by a Confidentiality
      agreement with or other obligation of secrecy to the Company or another party.
      

    (c)
      Government Order. Notwithstanding anything to the contrary in this Agreement,
      the Consultant shall not be precluded from disclosing any of the Confidential
      Information pursuant to a valid order of any governmental or regulatory
      authority, or pursuant to the order of any court or arbitrator.

    (d)
      Injunctive Relief. The Consultant agrees that, since a violation of this
      paragraph 3 would cause irreparable injury to the Company, and that there may
      not be an adequate remedy at law for such violation, the Company shall have
      the
      right in addition to any other remedies available at law or in equity, to enjoin
      the Consultant in a court of equity for violating the provisions of this
      paragraph 3.

    

    4.
      REPRESENTATION AND WARRANTIES OF THE COMPANY

    

    The
      Company hereby represents and warrants to the Consultant that as of the date
      hereof and as of the Closing Date (after giving effect to the transactions
      contemplated hereby):

    (a)
      Existence and Authority. The Company is a corporation duly organized and validly
      existing in good standing under the laws of its jurisdiction of incorporation
      and has full power and authority to own its respective property, carry on its
      respective business as no being conducted, and enter into and perform its
      obligations under this Agreement and to issue and deliver the Shares to be
      issued by it hereunder. The Company is duly qualified as a jurisdiction in
      which
      it is necessary to be so qualified to transact business as currently conducted.
      This Agreement, has been duly authorized by all necessary corporate action,
      executed, and delivered by the Company, and constitutes the legal, valid and
      binding obligation of the Company, enforceable against the Company in accordance
      with its terms subject to applicable bankruptcy, insolvency, reorganization,
      moratorium or other similar laws relating to or affecting the rights of
      creditors generally and to general principals of equity.

    (b)
      Authorization and Validity of Shares. The Shares have been duly authorized
      and
      are validly issued and outstanding, fully paid and non-assessable and free
      of
      any preemptive rights. THE Shares are not subject to any lien, pledge, security
      interest or other encumbrance.

    (c)
      Authorization of Agreement. The Company has taken all actions and obtains all
      consents or approvals necessary to authorize it to enter into this Agreement.
      

    (d)
      No
      Violation. Neither the execution or delivery of this Agreement, the issuance
      or
      delivery of Shares, the performance by the Company of its obligations under
      this
      Agreement, nor the consummation of the transactions contemplated hereby will
      conflict with, violate, constitute a breach of or a default (with the passage
      of
      time or otherwise) under, require the consent or approval of or filing with
      any
      person (other than consent and approvals which have been obtained and filings
      which have been made) under, or result in the imposition of a lien on or
      securities interest in any properties or assets of the Company, pursuant to
      the
      charter or bylaws of the Company, any award of any arbitrator or any agreement
      (including any agreement with stockholders), instruments, order, judgment,
      decree, statute, law, rule or regulation to which the Company is party or to
      which any such person or any of their respective properties or assets is
      subject.

    (e)
      Registration. The Shares have been, or will be upon the filing of an S-8
      Registration Statement, registered pursuant to the Securities Act of 1933,
      as
      amended and all applicable state laws.

    
      
        
        

      

      
        
        

        
          

        

      

      
        
        

      

    

    5.
      FILINGS

    

    The
      Company shall furnish to the Consultant, promptly after the sending or filing
      thereof, copies of all reports which the Company sends to its equity security
      holders generally, and copies of all reports and registration statements which
      the Company files with the Securities and Exchange Commission (the
“Commission”), any other securities exchange or the national Association of
      Securities Dealers, Inc. (“NASD”)

    

    6.
      SUPPLYING INFORMATION

    

    The
      Company shall cooperate with the Consultant in supplying such publicity
      available information as may be reasonably necessary for the Consultant to
      complete and file any information reporting forms.

    

    7.
      INDEMNIFICATION

    

    (a)
      The
      Company shall indemnify the Consultant from and against any and all expenses
      (including attorneys’ fees), judgments, fines, claims, cause of action,
      liabilities and other amounts paid (whether in settlement or otherwise actually
      and reasonably incurred) by the Consultant in connection with such action,
      suit
      or proceeding if (i) the Consultant was made a party to any action, suit or
      proceeding by reason of the fact that the Consultant rendered advice or services
      pursuant to this Agreement, and (ii) the Consultant acted in good faith and
      in a
      manner reasonably believed by the Consultant to be in or not opposed to the
      interests of the Company, and with respect to any criminal action or proceeding,
      had no reasonable cause or believe his conduct was unlawful. The termination
      of
      any action, suit or proceeding by judgment, order, settlement, conviction,
      or
      upon a plea of nolo contendere or its equivalent, shall not, of itself, create
      a
      presumption that the Consultant did not act in good faith in or not opposed
      to
      the best interests of the Company, and, with respect to any criminal action
      or
      proceeding, had reasonable cause to believe that his conduct was unlawful.
      Notwithstanding the foregoing, the Company shall not indemnify the Consultant
      with respect to nay claim, issue or matter as to which the consultant shall
      have
      been adjudged to be liable for gross negligence or willful misconduct in the
      performance other duties pursuant to this Agreement unless and only to the
      extent that the court in which such action or suit was brought shall determine
      upon application that, despite the adjunction of liability, but in view of
      all
      the circumstances of the case, the Consultant is fairly and reasonably entitled
      to indemnity for such expenses which such court shall deem proper.

    (b)
      The
      Consultant shall indemnify the Company from and against any and all expenses
      (including attorney’s fees), judgments, fines, claims, causes of action,
      liabilities and other amounts paid (whether in settlement or otherwise actually
      and reasonably incurred) by the Company in connection with such action, suit
      or
      proceeding if (i) the Company was made a party to any action, suit or proceeding
      by reason of the fact that the Consultant rendered advice or services pursuant
      to this Agreement, and (ii) the Consultant did not act in good faith and in
      a
      manner reasonably believed by the Consultant to be in or not opposed to the
      interests of the Company, and with respect to any criminal action or proceeding,
      did not reasonably believe his conduct was lawful. Notwithstanding the
      foregoing, the Consultant shall not indemnify the Company with respect to any
      claim, issue or matter as to which the Company shall have been adjudged to
      be
      liable for gross negligence or willful misconduct in connection with the
      performance of the Consultant’s duties pursuant to this Agreement unless and
      only to the extent that the court on which such action or suit was brought
      shall
      determine upon application that, despite the adjunction of liability, in view
      of
      all circumstances of the case, the Company is fairly and reasonably entitled
      to
      indemnify for such expenses which such court shall deem proper.

    

    8.
      INDEPENDENT CONTRACTOR STATUS

    

    It
      is
      expressly understood and agreed that this is a consulting agreement only and
      does not constitute an employer-employee relationship. Accordingly, the
      Consultant agrees that the consultant shall be solely responsible for payment
      of
      his own taxes or sums due to the federal, state, or local governments, overhead,
      workmen’s compensation, fringe benefits, pension contributions and other
      expenses. It is further understood and agreed that the Consultant is an
      independent contractor and the company shall have no right to control the
      activities of the Consultant other than during the express period of time in
      which the Consultant is performing services hereunder, and that such services
      provided hereunder and not because of any presumed employer-employee
      relationship. The Consultant shall have no authority to bind the company. The
      parties further acknowledge that the Company’s services hereunder are not
      exclusive, but that the Consultant shall be performing services and undertaking
      other responsibilities, for and with other entities or persons, which may
      directly or indirectly compete with the Company. Accordingly, the services
      of
      the Consultant hereunder are on a part time basis only, and the Company shall
      have no discretion, control of, or interest in, the 

    
      
        
        

      

      
        
        

        
          

        

      

      
        
        

      

    

    Consultant’s
      services which are not covered by the terms of the Agreement. The Company hereby
      waives any conflict of interest which now exists or may hereafter arise with
      respect to Consultant’s current employment and future employment.

    

    9.
      NOTICE

    

    All
      notices provided by this Agreement shall be in writing and shall be given by
      facsimile transmission, overnight courier, by registered mail or by personal
      delivery, by one party to the other, addressed to such other party at the
      applicable address set forth below, or to such other address as may be given
      for
      such purpose by such other party by notice duly given hereunder. Notice shall
      be
      deemed properly given on the date of the delivery.

    

    To
      Consultant: 

    

    To
      the
      Company: 1809 E Broadway St., Ste 346

    Oviedo,
      FL. 32765

    

    10.
      MISCELLANEOUS

    

    (a)
      Waiver. Any term or provision of this Agreement may be waived at any time by
      the
      party entitled to the benefit thereof by a written instrument duly executed
      by
      such party.

    (b)
      Entire Agreement. This Agreement contains the entire understanding between
      the
      parties hereto with respect to the transactions contemplated hereby, and may
      not
      be amended, modified, or altered except by an instrument in writing signed
      by
      the party against whom such amendment, modification, or alteration is sought
      to
      be enforced. This Agreement supercedes and replaces all other agreements between
      the parties with respect to any services to be performed by

    the
      Consultant of behalf of the Company.

    (c)
      Governing Law. This Agreement shall be construed and interpreted in accordance
      with the laws of the State of Florida.

    (d)
      Binding Effect. This Agreement shall bind and inure to the benefit of the
      parties hereto and their respective heirs, executors, administrators, successors
      and assigns.

    (e)

      Construction. The captions and headings contained herein are inserted for
      convenient reference only, are not a part hereof and the same shall not limit
      or
      construe the provisions to which they apply. Reference in this agreement to
      “paragraphs” is to the paragraphs in this Agreement, unless otherwise
      noted.

    (f)
      Expenses. Each party shall pay and be responsible for the cost and expanses,
      including, without limitations, attorney’s fees, incurred by such party in
      connection with negotiation, preparation and execution of this Agreement and
      the
      transactions contemplated hereby.

    (g)
      Assignment. No party hereto may assign any of its rights or delegate any of
      its
      obligations under this Agreement without the express written consent of the
      other party hereto.

    (h)
      No
      Rights to Others. Nothing herein contained or implied is intended or shall
      be
      construed to confer upon or give to any person, firm or corporation, other
      than
      the parties hereto.

    (i)
      Counterparts. This Agreement may be executed simultaneously in two counterparts,
      each of which shall be deemed an original, but both of which together shall
      constitute on and the same agreement, binding upon both parties hereto,
      notwithstanding that both parties are not signatories to the original or the
      same counterpart.

    

    IN
      WITNESS WHEREOF, the parties have executed this Agreement on the date and year
      first above written.

    

    PROMOTORA
      VALLE HERMOSA CORPORATION

    By:President
      and CEO

    

    

    By:

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00128-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00128-of-00352.parquet"}]]