Document:

Exhibit 4.18

SHARE PURCHASE AGREEMENT

 

This Share Purchase
Agreement (the “Agreement”) is made and entered into as May 19, 2020 by and between:

 

(1)       Mercurity
Fintech Holding Inc., an exempted company with limited liability incorporated under the laws of the Cayman Islands (the “Company”);
and

 

(2)       Universal
Hunter (BVI) Limited, a company with limited liability incorporated under the laws of the British Virgin Islands (the “Investor”).

 

Each of the Company and the Investor is referred to as a “Party”
and collectively as “Parties.”

 

Whereas, the
Investor desires to invest in the Company by subscribing for a certain number of ordinary shares to be issued by the Company pursuant
to the terms and subject to the conditions of this Agreement;

 

Whereas, the
Company desires to issue and sell a certain number of ordinary shares to the Investor pursuant to the terms and subject to the
conditions of this Agreement; and

 

Whereas, the
Parties desire to enter into this Agreement and make the respective representations, warranties, covenants and agreements set forth
herein on the terms and conditions set forth herein.

 

Now, Therefore,
in consideration of the foregoing recitals and the mutual promises made in this Agreement, and for other good and valuable consideration,
the receipt and sufficiency of which is hereby acknowledged, the Parties hereby agree as follows:

 

1.       Definitions

 

The following terms
used in this Agreement shall be construed to have the meaning set forth or referenced below.

 

	“ADS”	 	means American depositary share of the Company, each representing 360 Shares effective from May 19, 2020 and 180 Shares prior to May 19, 2020; 
	“Affiliates”	 	means, with respect to any specified Person, any other Person who or which, directly or indirectly, Controls, is Controlled by, or is under common Control with such specified Person, including, without limitation, any officer, director, employee, member, partner or shareholder of such Person and any venture capital fund now or hereafter existing that is Controlled by or under common Control with one or more general partners or managing members of, or shares the same management company with, such Person; 
	“Agreement”	 	means this Share Purchase Agreement; 
	“Charter Documents”	 	mean, as to a Person, such Person’s memorandum and articles of association, certificate or articles of incorporation, by-laws, partnership agreement, joint venture agreements, formation agreement, limited liability company agreement and other organizational documents;
	“Closing”	 	means any of the Closing I and the Closing II, individually, and the “Closings” means Closing I and the Closing II, collectively; 

 

     

     

    

 

	“Closing I”	 	has the meaning given to it in Section 2.3(a); 
	“Closing II”	 	has the meaning given to it in Section 2.3(a); 
	“Company”	 	has the meaning given to it in the preamble of this Agreement;
	“Confidential Information”	 	has the meaning given to it in Section 10.1;
	“Control”	 	means the possession, directly or indirectly, of the power to direct or cause the direction of the management of a Person, whether through the ownership of voting securities, by contract, credit arrangement or proxy, as trustee, executor, agent or otherwise. For the purpose of this definition, a Person shall be deemed to Control another Person if such first Person, directly or indirectly, owns or holds more than fifty percent (50%) of the voting power in such other Person. The tem “Controlled” has the meaning correlative to the foregoing;
	“Disclosing Party”	 	has the meaning given to it in Section 10.4;
	“Exchange Act”	 	means the United States Exchange Act of 1934, as amended, and the rules and regulations promulgated thereunder;
	“Governmental Authority”	 	means (a) any nation or government or any nation, federal, state, province, municipality, local, autonomous region or any other political subdivision thereof; (b) any entity, authority or body exercising executive, legislative, judicial, regulatory or administrative functions of or pertaining to government and any government authority, agency, department, board, commission or instrumentality or any political subdivision thereof, including any entity or enterprise owned or controlled by a government or a public international organization; or (c) any court, tribunal or arbitrator;
	“Group”	 	means, collectively, the Company and its Subsidiaries;
	“Group Company”	 	means any member of the Group, individually, and the “Group Companies” means two or more members of the Group, collectively;
	“Group Material Adverse Effect”	 	means a material adverse effect on the business, assets (including intangible assets), liability, financial condition, property, prospects or results of operations of the Group, taken as a whole;
	“HKIAC”	 	has the meaning given to it in Section 11.9;
	“Indemnified Person”	 	has the meaning given to it in Section 9.2;
	“Indemnifying Person”	 	has the meaning given to it in Section 9.2;
	“Key Employee”	 	means any executive-level employee (including division director and vice president-level positions);
	“Law”	 	means any statute, law, ordinance, regulation, rule, code, order, requirement or rule of law (including common law), official policy, rule or interpretation of any Governmental Authority with jurisdiction over the Investor and the Group Companies, as the case may be;

 

     

     

    

 

	“Lien”	 	means any mortgage, pledge, deed of trust, hypothecation, right of others, claim, security interest, encumbrance, burden, title defect, title retention agreement, lease, sublease, license, occupancy agreement, easement, covenant, condition, encroachment, voting trust agreement, charge, option, right of first offer, negotiation or refusal, proxy, lien, charge, adverse claim or other restrictions (including restrictions on transfer), or limitations of any nature whatsoever, including such liens as may arise under any contract;
	“Long-Stop Date”	 	has the meaning given to it in Section 8.1(c);
	“Party”	 	has the meaning given to it in the preamble of this Agreement; 
	“Person”	 	means any individual, corporation, partnership, trust, limited liability company, company limited by shares, unincorporated association or other entity;
	“PRC”	 	means the People’s Republic of China, excluding the Hong Kong Special Administrative Region, Macau Special Administrative Region and the Separate Customs Territory of Taiwan, Penghu, Kinmen and Matsu;
	“Purchased Shares”	 	has the meaning given to it in Section 2.1;
	“SEC”	 	has the meaning given to it in Section 4.8(a);
	“SEC Documents”	 	has the meaning given to it in Section 4.8(a);
	“Securities Act”	 	means the United States Securities Act of 1933, as amended, and the rules and regulations promulgated thereunder;
	“Investor”	 	has the meaning given to it in the preamble of this Agreement;
	“Shares”	 	means the issued and outstanding ordinary shares of the Company, par value US$0.00001 per share;
	“Tax” or “Taxes”	 	means any and all national, federal, state, provincial, municipal and local taxes of any country, assessments and other governmental charges, duties, impositions and liabilities, including taxes based upon or measured by gross receipts, income, profits, capital gains, sales, use and occupation, and value added, ad valorem, stamp transfer, franchise, building, vehicle, land use, land appreciation, city and rural construction, tariff, withholding, payroll, recapture, employment, additional education, excise and property taxes, adjustment taxes, together with all interest, penalties and additions imposed with respect to such amounts and any obligations under any agreements or arrangements with any other Person with respect to such amounts and including any liability for taxes of a predecessor entity;
	“Transaction”	 	means the transaction contemplated by this Agreement.

 

2.            Purchase
and Sales of Shares

 

2.1            Sale
and Issuance of the Purchased Shares. Subject to the terms and conditions of this Agreement, and in reliance upon the representations,
warranties, and covenants in this Agreement, at the Closing, the Investor shall subscribe for and purchase from the Company, and
the Company shall issue and sell to the Investor a certain number of Shares based on the closing and payment schedule set forth
in Schedule A (the “Purchased Shares”) at a per share price that is equal to the daily average
closing price of the Company’s ADSs (each representing 180 Shares prior to May 19, 2020) during the period from April 13,
2020 to May 8, 2020 adjusted to reflect the ADS-to-Share ratio. The aggregate number of Purchased Shares to be issued by the Company
to the Investor at the Closings is 300,000,000 Shares.

 

     

     

    

 

2.2            Consideration.
The consideration to be paid by the Investor for the Purchased Shares at the Closing I and the Closing II shall be US$300,000 and
US$700,000, respectively, in cash (the “Cash Consideration”) to be paid pursuant to Section 2.3(c).

 

2.3            Closings.

 

(a)            The
purchases and sales of the Purchased Shares shall take place remotely via the exchange of documents and signatures no later than
May 23, 2020 (the “Closing I”) and November 18, 2020 (the “Closing II”), respectively,
at the time and place as the Company and the Investor mutually agreed upon, orally or in writing. Each of the Closing I and the
Closing II will be deemed to be effective as of the close of business on the date of such Closing for tax and accounting purposes.

 

(b)            At
the Closing, conditioned upon the fulfillment or the waiver by the Purchaser of all conditions set forth in Section 6 of
this Agreement, the Company shall deliver to the Investor a certified copy of the register of members of the Company reflecting
the issuance of the Purchased Shares to the Investor at such Closing.

 

(c)            At
the Closing, the Investor shall pay the Cash Consideration by wiring immediately available funds to the bank account(s) designated
by the Company or pursuant to written wire instruction otherwise delivered to the Investor based on the closing and payment schedule
set forth in Schedule A:

 

3.            Representations
and Warranties of the Investor

 

The Investor hereby
represents and warrants to the Company that the following representations are true and complete as of the date hereof and will
be true and correct as of the date of the Closing, except as otherwise indicated.

 

3.1            Authorization.
The Investor represents and warrants that it is legally competent to enter into this Agreement. This Agreement, when executed and
delivered by the Investor, will constitute valid and legally binding obligations of the Investor, enforceable in accordance with
their terms, except as limited by applicable bankruptcy, insolvency, reorganization, moratorium, fraudulent conveyance, and any
other laws of general application affecting enforcement of creditors’ rights generally, and as limited by Laws relating to
the availability of specific performance, injunctive relief, or other equitable remedies.

 

3.2            Enforceability.
This Agreement, when executed and delivered by the Investor, shall constitute valid and legally binding obligations of him, enforceable
against the Investor in accordance with their respective terms, except in each case as limited by applicable bankruptcy, insolvency,
reorganization, moratorium, fraudulent conveyance, and any other Laws of general application affecting enforcement of creditors’
rights generally, and as limited by Laws relating to the availability of specific performance, injunctive relief, or other equitable
remedies.

 

3.3            Accredited
Investor. The Investor is an accredited investor as defined in Rule 501(a) of Regulation D promulgated under the Securities
Act.

 

3.4            Restricted
Securities. The Investor understands that the Shares have not been registered under the Securities Act, by reason of a specific
exemption from the registration provisions of the Securities Act which depends upon, among other things, the bona fide nature of
the investment intent and the accuracy of the Investor’s representations as expressed herein. The Investor understands that
the Shares are “restricted securities” under applicable U.S. federal and state securities laws and that, pursuant to
these laws, the Investor must hold the Shares indefinitely unless they are registered with the SEC, or an exemption from such registration
requirements is available.

 

     

     

    

 

4.            Representation
and Warranties of the Company

 

The Company hereby,
represents and warrants to the Investor that the following representations are true and complete as of the date hereof and will
be true and correct as of the date of the Closing, except as otherwise indicated.

 

4.1            Capitalization
of the Company. The Purchased Shares will have been validly issued, fully paid and non assessable as of the Closing. Upon the
Closing, the Investor will acquire title to the Purchased Shares, free and clear of all Lien.

 

Except as set forth
in Schedule B of this Agreement, which correctly and accurately reflects (i) the aggregate number of issued and outstanding
ordinary shares of the Company as of the date of this Agreement, and (ii) the aggregate number of ordinary shares issuable under
all outstanding options, all outstanding warrants and all other outstanding securities or obligations which, by their terms, whether
directly or indirectly, may be exercisable or exchangeable for, convertible into, or require the Company to issue, ordinary shares
of the Company, there are no outstanding options, warrants, rights (including conversion or preemptive rights and rights of first
refusal or similar rights) or agreements, orally or in writing, to purchase or acquire from the Company any shares of the Company,
or any securities convertible into or exchangeable for shares of the Company.

 

4.2            Authorization.
The Company has full power and authority to enter into this Agreement. This Agreement, when executed and delivered by the Company,
will constitute valid and legally binding obligations of the Company, enforceable in accordance with their terms, except as limited
by applicable bankruptcy, insolvency, reorganization, moratorium, fraudulent conveyance, and any other Laws of general application
affecting enforcement of creditors’ rights generally, and as limited by Laws relating to the availability of specific performance,
injunctive relief, or other equitable remedies.

 

4.3            Compliance
with Laws and Other Instruments. Each Group Company is in compliance with all applicable Laws in all aspects, except for those
noncompliance where the failure to do so would not individually or in the aggregate have a Group Material Adverse Effect.

 

Except as otherwise
disclosed in the SEC Documents, none of the Group Companies is in violation of its Charter Documents, shareholders agreements,
as appropriate, or equivalent constitutive documents as in effect.

 

4.4            Governmental
Consents and Filings. Assuming the accuracy of the representations made by the Investor in Section 3 of this Agreement,
no consent, approval, order or authorization of, or registration, qualification, designation, declaration or filing with, any national,
provincial, municipal, local, autonomous region and Governmental Authority is required on the part of the Company in connection
with the consummation of the Transaction.

 

4.5            No
Litigation. Except as otherwise disclosed in the SEC Documents, (1) there is no material claim, action, suit, proceeding, arbitration,
complaint, charge or investigation pending or, to the knowledge of the Company, currently threatened against any Group Company,
and (2) there is no material action, suit, proceeding or investigation by any Group Company pending or which any Group Company
intends to initiate. There is no claim, action, suit, proceeding, arbitration, complaint, charge or investigation pending against
the any Group Company that challenges, or could have the effect of preventing, delaying, making illegal, imposing limitations or
conditions on, or otherwise interfering with, the Transaction.

 

     

     

    

 

4.6            Enforceability.
This Agreement, when executed and delivered by the Company, shall constitute valid and legally binding obligations of the Company,
enforceable against the Company in accordance with its respective terms, except as limited by applicable bankruptcy, insolvency,
reorganization, moratorium, fraudulent conveyance, and any other Laws of general application affecting enforcement of creditors’
rights generally, and as limited by Laws relating to the availability of specific performance, injunctive relief, or other equitable
remedies.

 

4.7            No
Insolvency.

 

(a)            No
Group Company is insolvent.

 

(b)            There
are no circumstances which would entitle any Person to successfully present a petition for the winding-up or administration of
any Group Company or to appoint a receiver over the whole or any part of the undertaking or assets of any Group Company.

 

4.8            SEC
Documents.

 

(a)            The
Company has filed or furnished, as applicable, all required reports, schedules, forms, certifications, prospectuses, and registration,
proxy and other statements with the United States Securities and Exchange Commission (the “SEC”) since
August 8, 2014 (collectively and together with all documents filed on a voluntary basis on Form 6-K, and in each case including
all exhibits and schedules thereto and documents incorporated by reference therein, and in its effective form (the “SEC
Documents”) in material aspects.

 

(b)            Each
of the SEC Documents, at the time of its filing or being furnished, has complied in all material respects, with the applicable
requirements of the Exchange Act, the Securities Act and the Sarbanes-Oxley Act of 2002, and any rules and regulations promulgated
thereunder applicable to the SEC Documents. As of their respective dates (or, if amended prior to the date hereof, as of the date
of such amendment), the SEC Documents did not, and any SEC Documents filed with or furnished to the SEC Documents did not, and
any SEC Documents filed with or furnished to the SEC subsequent to the date hereof will not, contain any untrue statement of a
material fact or omit to state a material fact required to be stated therein or necessary to make the statements made therein,
in light of the circumstances in which they were made, not misleading.

 

5.            Covenants
and Agreements of the Investor

 

5.1            Required
Approvals. As promptly as practicable after the date of this Agreement, and in any event within the applicable time period
prescribed by Law, the Investor shall make all filings and notifications required by Law to be made by himself in connection with
the Transaction, if any. The Investor shall cooperate with the Company and its Affiliates with respect to all filings and notifications
that are required by Law to be made in connection with the Transactions.

 

5.2            Notification.
Between the date of this Agreement and the Closing, the Investor will promptly notify the Company in writing if the Investor becomes
aware of any fact or condition that causes or constitutes a breach of the Investor and warranties as set forth in Section 3,
or if the Investor becomes aware of the occurrence after the date of this Agreement of any fact or condition that would (except
as expressly contemplated by this Agreement) cause or constitute a breach of any such representation or warranty had such representation
or warranty been made as of the time of occurrence or discovery of such fact or condition. During the same period, the Investor
will promptly notify the Company of the occurrence of any breach of any covenant of the Investor in this Section 5 or of
the occurrence of any event that may make the satisfaction of the conditions in Section 6 impossible or unlikely.

 

     

     

    

 

5.3            Best
Efforts. Between the date of this Agreement and the Closing, the Investor shall, and shall cause each Group Company to, use
its best efforts to take, or cause to be taken, all actions, and to do, or cause to be done and cooperate with each other to do,
all things necessary, proper or advisable to perform all of the obligations set forth in Section 5 and cause the conditions
in Section 6 to be satisfied. The Investor shall, and cause each of its Affiliates to, exert best efforts to take, or cause
to be taken, all actions, and to do, or cause to be done all things reasonably necessary, proper or advisable under applicable
laws or otherwise to obtain all consents, approvals or conditions, if any, that may be required before the Closing. The Investor
shall cooperate as requested by the Company to obtain all such consents, approvals or conditions.

 

6.            Conditions
to the Company’s Obligations at Closing

 

The obligations of
the Company to issue the Purchased Shares to the Investor at the Closing are subject to the fulfillment, on or before such Closing,
of each following condition, unless otherwise waived:

 

6.1            Representations
and Warranties. The representations and warranties of the Investor contained in Section 3 shall be true, correct and
complete in all material respects as of such Closing.

 

6.2            Performance.
The Investor shall have performed and complied with, in all material respects, all covenants, agreements, obligations and conditions
contained in this Agreement that are required to be performed or complied with by the Investor on or before such Closing.

 

6.3            Document
Delivery. The Investor shall have delivered to the Company a duly executed copy of this Agreement.

 

7.            Conditions
of the Investor’s Obligations at Closing

 

The obligations of
the Investor to subscribe and purchase the Purchased Shares at the Closing are subject to the fulfillment, on or before such Closing,
of each following condition, unless otherwise waived:

 

7.1            Representations
and Warranties. The representations and warranties of the Company contained in Section 4 shall be true, correct and
complete in all material respects as of such Closing, except where such breach of representations and warranties, individually
or in the aggregate, could not reasonably be expected to result in a Group Material Adverse Effect.

 

7.2            Performance.
The Company shall have performed and complied with, in all material respects, all covenants, agreements, obligations and conditions
contained in this Agreement that are required to be performed or complied with by them on or before such Closing.

 

7.3            Document
Delivery. The Company shall have delivered to the Investor a duly executed copy of this Agreement.

 

     

     

    

 

8.            Termination

 

8.1            Termination
Events. This Agreement may, be notice given prior to or at the Closing, be terminated:

 

(a)            by
either the Company or the Investor if a material breach of any provision of this Agreement has been committed by another Party
and such breach has not been waived or rectified within thirty (30) days after the breach;

 

(b)            by
mutual consent of the Company and the Investor; or

 

(c)            by
the Company or the Investor if the Closing II has not occurred (other than through the failure of any Party seeking to terminate
this Agreement to comply fully with its or their obligations under this Agreement) on or December 31, 2020 (the “Long-Stop
Date”), or such later date as the Parties may agree upon.

 

8.2            Effect
of Termination. Each Party’s right of termination under Section 8.1 is in addition to any other rights it may have
under this Agreement or otherwise, and the exercise of a right of termination will not be an election of remedies. If this Agreement
is terminated pursuant to Section 8.1, all further obligations of the Parties under this Agreement will terminate; provided,
however, that if this Agreement is terminated by a Party because of the breach of the Agreement by another Party or because
one or more of the conditions to the terminating Party’s obligations under this Agreement is not satisfied as a result of
another Party’s failure to comply with its obligations under this Agreement, the terminating Party’s right to pursue
all legal remedies will survive such termination unimpaired.

 

9.            Indemnification
and Remedies

 

9.1            Survival.

 

(a)            All
representations, warranties, covenants, and obligations in this Agreement, and any certificate, document, or other writing delivered
pursuant to this Agreement will survive for one (1) year after the Closing and the consummation and performance of the Transactions.
The covenants and other agreements of each Party contained in this Agreement shall survive the Closing until fully discharged in
accordance with their terms, except for those covenants and agreements which shall be complied with or discharged prior to the
Closing in accordance with the terms of this Agreement.

 

(b)            If
written notice of a claim for indemnification has been given in accordance with this Section 9.1 prior to the time at which
the applicable representations, warranties, covenants or other agreements would otherwise terminate pursuant to the foregoing,
then the relevant representations, warranties, covenants or other agreements shall survive such time as to such claim, until such
claim has been finally resolved.

 

(c)            The
waiver of any condition relating to any representation, warranty, covenant, or obligation will not affect the right to indemnification,
payment, reimbursement, or other remedy based upon such representation, warranty, covenant, or obligation.

 

9.2            Indemnification.

 

From and after the
date of the Closing, each Party, as applicable (the “Indemnifying Person”), shall indemnify and hold
the other relevant Parties and their respective directors, officers and agents (collectively, the “Indemnified Person”)
harmless from and against any losses, claims, damages, liabilities, judgments, fines, obligations, expenses and liabilities of
any kind or nature whatsoever, including but not limited to any investigative, legal and other expenses incurred in connection
with, and any amounts paid in settlement of, any pending or threatened legal action or proceeding, and any taxes or levies that
may be payable by such person by reason of the indemnification of any indemnifiable loss hereunder (collectively, “Losses”)
resulting from or arising out of: (i) the breach of any representation or warranty of the Indemnifying Person contained in this
Agreement, or (ii) the violation or nonperformance, partial or total, of any covenant or agreement of the Indemnifying Person contained
in this Agreement. In calculating the amount of any Losses of an Indemnified Person hereunder, there shall be subtracted the amount
of any insurance proceeds and third-party payments received by the Indemnified Person with respect to such Losses, if any.

 

     

     

    

 

9.3            Third-Party
Claims.

 

(a)            The
Indemnified Person shall give notice of the assertion of a Third-Party Claim to the Indemnifying Person; provided, however,
that no failure or delay on the part of an Indemnified Person in notifying an Indemnifying Person will relieve the Indemnifying
Person from any obligation under this Section 9 except to the extent that the failure or delay materially prejudices the
defense of the Third-Party Claim by the Indemnifying Person.

 

(b)            (i)            Except as provided
in Section 9, the Indemnifying Person may elect to assume the defense of the third-party claim with counsel satisfactory
to the Indemnified Person by (a) giving notice to the Indemnified Person of its election to assume the defense of the Third-Party
Claim and (b) giving the Indemnified Person evidence acceptable to the Indemnified Person that the Indemnifying Person has adequate
financial resources to defend against the Third-Party Claim and fulfill its obligations under this Section 9, in each case
no later than ten (10) days after the Indemnified Person gives notice of the assertion of a Third-Party Claim under Section
9.3(a).

 

(ii)            If
the Indemnifying Person elects to assume the defense of a Third-Party Claim: (A) it shall diligently conduct the defense and, so
long as it diligently conducts the defense, shall not be liable to the Indemnified Person for any Indemnified Person’s fees
or expenses subsequently incurred in connection with the defense of the Third-Party Claim other than reasonable costs of investigation,
(B) the election will conclusively establish for purposes of this Agreement that the Indemnified Person is entitled to relief under
this Agreement for any loss arising, directly or indirectly, from or in connection with the Third-Party Claim, (C) no compromise
or settlement of such Third-Party Claim may be effected by the Indemnifying Person without the Indemnified Person’s consent
unless (I) there is no finding or admission of any violation by the Indemnified Person of any Laws or any rights of any Person,
(II) the Indemnified Person receives a full release of and from any other claims that may be made against the Indemnified Person
by the Third Party bringing the Third-Party Claim, and (III) the sole relief provided is monetary damages that are paid in full
by the Indemnifying Person, and (D) the Indemnifying Person shall have no liability with respect to any compromise or settlement
of such claims effected without its consent.

 

(iii)            If
the Indemnifying Person does not assume the defense of a Third-Party Claim in the manner and within the period provided in Section
9.3(b)(ii), or if the Indemnifying Person does not diligently conduct the defense of a Third-Party Claim, the Indemnified Person
may conduct the defense of the Third-Party Claim at the expense of the Indemnifying Person and the Indemnifying Person shall be
bound by any determination resulting from such Third-Party Claim or any compromise or settlement effected by the Indemnified Person.

 

(c)            Notwithstanding
the foregoing, if an Indemnified Person determines in good faith that there is a reasonable probability that a Third-Party Claim
may adversely affect it or any Affiliate other than as a result of monetary damages for which it would be entitled to relief under
this Agreement, the Indemnified Person may, by notice to the Indemnifying Person, assume the exclusive right to defend, compromise,
or settle such Third-Party Claim.

 

     

     

    

 

(d)            Notwithstanding
the provisions of Section 11.12, the Parties consent to the nonexclusive jurisdiction of any court in which a proceeding
is brought against any Indemnified Person for purposes of determining any claim that an Indemnified Person may have under this
Agreement with respect to such proceeding or the matters alleged therein.

 

(e)            With
respect to any Third-Party Claim subject to this Section 9.3: (i) any Indemnified Person and any Indemnifying Person, as
the case may be, shall keep the other Person fully informed of the status of such Third-Party Claim and any related proceeding
at all stages thereof where such Person is not represented by its own counsel, and (ii) both the Indemnified Person and the Indemnifying
Person, as the case may be, shall render to each other such assistance as they may reasonably require of each other and shall cooperate
in good faith with each other in order to ensure the proper and adequate defense of any Third-Party Claim.

 

(f)            In
addition to Section 10, with respect to any Third-Party Claim subject to this Section 9.3, the Parties shall cooperate
in a manner to reserve in full (to the extent possible) the confidentiality of all confidential information and the attorney-client
and work product privileges. In connection therewith, each Party agrees that: (i) it shall use its best efforts, in respect of
any Third-Party Claim in which it has assumed or participated in the defense, to avoid production of confidential information (consistent
with applicable Law and rules of procedure) and (ii) all communications between any Party and counsel responsible for or participating
in the defense of any Third-Party Claim shall, to the extent possible, be made so as to preserve any applicable attorney-client
or work-product privilege.

 

(g)            Any
claim under this Section 9.3 for any matter involving a Third-Party Claim shall be indemnified, paid, or reimbursed promptly.
If the Indemnified Person shall for any reason assume the defense of a Third-Party Claim, the Indemnifying Person shall reimburse
the Indemnified Person on a monthly basis for the costs of investigation and the reasonable fees and expenses of counsel retained
by the Indemnified Person.

 

9.4            Indemnitee
Negligence. The provisions in this Section 9 shall be enforceable regardless of whether the liability is based upon
past, present or future acts, claims or Laws and regardless of whether any Person (including the Person from whom relief is sought)
alleges or proves the sole, concurrent, contributory, or comparative negligence of the Person seeking relief, or the sole or concurrent
strict liability imposed upon the person seeking relief.

 

10.            Confidentiality
and Press Release

 

10.1            Disclosure
of Terms. The terms and conditions of this Agreement, any term sheet or memorandum of understanding entered into pursuant to
the transactions contemplated hereby and thereby, all exhibits and schedules attached hereto and thereto, and the transactions
contemplated hereby and thereby (collectively, the “Confidential Information”), including their existence,
shall be considered confidential information and the Parties hereto shall not, and shall procure their respective Affiliates not
to, disclose to any third party except as permitted in accordance with the provisions set forth below.

 

10.2            Press
Release. Any public announcement, including any press release, communication to employees customers, suppliers, or others having
dealings with the Company, or similar publicity with respect to this Agreement or the Transaction, will be issued, at such time,
in such manner and containing such content as the Company deems appropriate.

 

     

     

    

 

10.3        Permitted
Disclosure. Notwithstanding anything in the foregoing to the contrary:

 

(a)           the
Company may disclose any portion of the Confidential Information to its current officers, directors, Key Employees, investment
bankers, lenders, accountants, auditors, business or financial advisors, and attorneys, in each case only where such persons or
entities are under appropriate non-disclosure obligations imposed by professional ethics, law or otherwise; and

 

(b)           the
confidentiality obligations set out in Section 10.1 above do not apply to:

 

(i)           information
which was in the public domain or otherwise known to the relevant Party before it was furnished to it by another Party or, after
it was furnished to that Party, entered the public domain otherwise than as a result of (i) a breach by that Party of this Section
10, or (ii) a breach of a confidentiality obligation by the discloser, where the breach was known to that Party;

 

(ii)           information
the disclosure of which is necessary in order to comply with any applicable Law, the order of any court, the requirements of a
stock exchange or to obtain tax or other clearances or consents from any relevant authority; or

 

(iii)           information
disclosed by any director of the Company to its appointer or any of its Affiliates or otherwise in accordance with the foregoing
provisions of this Section 10.

 

10.4           Legally
Required Disclosure. In the event that any Party is requested by any Governmental Authority or becomes legally required (including,
pursuant to securities Laws and regulations) to disclose, under applicable Laws, the existence of this Agreement, or the content
of any of the financing terms in contravention of the provisions of this Section 10, such Party (the “Disclosing
Party”) shall provide the other Party with prompt written notice of that fact and shall consult with the other Party
regarding such disclosure. The Disclosing Party shall, to the extent possible and with the cooperation and reasonable efforts of
the other Party, seek a protective order, confidential treatment or other appropriate remedy.  In such event, the Disclosing
Party shall furnish only that portion of the information which is legally required to be disclosed and shall exercise reasonable
efforts to obtain reliable assurance that confidential treatment will be accorded to such information.

 

10.5           Other
Information. The provisions of this Section 10 shall be in addition to, and not in substitution for, the provisions
of any separate non-disclosure agreement executed by any of the Parties hereto with respect to the Transactions.

 

11.         Miscellaneous

 

11.1           Fees
and Expenses. Except as otherwise provided in this Agreement or the other documents to be delivered pursuant to this Agreement,
each Party will bear its respective fees and expenses incurred in connection with the preparation, negotiation, execution, and
performance of this Agreement and the consummation and performance of the Transaction, including all fees and expenses of its officers,
directors, partners, employees, agents or representatives.  The obligation of each Party to bear its own fees and expenses
will be subject to any rights of such Party arising from a breach of this Agreement by another Party.

 

The stamp duty in connection
with the Transaction shall be borne equally by the Investor (on the one hand) and the Company (on the other hand). The Investor
shall be solely responsible for his own income tax, capital gain tax or other forms of Taxes payable by the Investor under the
applicable Laws.

 

     

     

    

           

11.2           Further
Assurance. The Parties will (a) execute and deliver to each other such other documents and (b) do such other acts and things
as a Party may reasonably request for the purpose of carrying out the intent of this Agreement, the Transaction, and the documents
to be delivered pursuant to this Agreement.

 

11.3           Entire
Agreement. This Agreement supersedes all prior agreements, whether written or oral, between the Parties with respect to its
subject matter (including any letter of intent and, upon the Closing, any confidentiality obligation to which the Company is subject)
and constitutes a complete and exclusive statement of the terms of the agreement between the Parties with respect to the subject
matter of this Agreement.

 

11.4           Amendment.
This Agreement may only be amended, supplemented, or otherwise modified by the Company and the Investor in writing.

 

11.5           Assignments
and Successors. The terms and conditions of this Agreement shall inure to the benefit of and be binding upon the respective
successors and assigns of the Parties. Nothing in this Agreement, express or implied, is intended to confer upon any Party other
than the Parties hereto or their respective successors and assigns any rights, remedies, obligations, or liabilities under
or by reason of this Agreement, except as expressly provided in this Agreement.

 

11.6           No
Third-Party Rights. Other than the Indemnified Persons and the Parties, no Person will have any legal or equitable right, remedy,
or claim under or with respect to this Agreement. This Agreement may not be amended or terminated without the consent of any Person
who is a Party to the Agreement.

 

11.7           Remedies
Cumulative. The rights and remedies of the Parties under this Agreement are cumulative and not alternative.

 

11.8           Governing
Law. This Agreement shall be governed by and construed in accordance with the laws of the State of New York, without regard
to the principles of conflicts of law thereof.

 

11.9           Dispute
Resolution. Any dispute, controversy or claim arising out of or relating to this Agreement, or the interpretation, breach,
termination or invalidity thereof, shall, so far as it is possible, be settled by arbitration in accordance with the UNCITRAL Arbitration
Rules as at present in force and as may be amended by the rest of this Section 11. The appointing authority shall
be Hong Kong International Arbitration Centre (“HKIAC”). The seat of the arbitration shall be Hong Kong.
There shall be three (3) arbitrators. The Investor, on the one hand, and the Company, on the other hand, shall be entitled
to designate one arbitrator each. The two (2) arbitrators shall consult with each other to agree upon the selection of a third
arbitrator. The arbitration shall be conducted in the English language. Evidence and testimony may be presented in any language,
including a language other than English providing it is accompanied by an English translation thereof (which translation shall
have been certified and prepared or given at the sole cost of the Party offering such evidence or testimony). The arbitral
award shall be in English writing and, unless the parties to the arbitration agree otherwise, shall state the reasons upon which
it is based. The award shall be final and binding on the parties to the arbitration.

 

11.10           Attorney’s
Fees. In the event any claim, action, suit, proceeding, arbitration, complaint, charge or investigation is brought in respect
of this Agreement or any of the documents referred to in this Agreement, the prevailing Party shall be entitled to recover reasonable
attorneys’ fees and other costs incurred in such claim, action, suit, proceeding, arbitration, complaint, charge or investigation,
in addition to any relief to which such Party may be entitled under applicable Law.

 

     

     

    

 

11.11           Enforcement
of Agreement. Each Party acknowledges and agrees that the other Party would be irreparably harmed if any of the provisions
of this Agreement are not performed in accordance with their specific terms and that any breach of this Agreement by such Party
could not be adequately compensated in all cases by monetary damages alone. Accordingly, each Party agrees that, in addition to
any other right or remedy to which the other Party may be entitled at law or in equity, such Party shall be entitled to enforce
any provision of this Agreement by a decree of specific performance and to obtain temporary, preliminary, and permanent injunctive
relief to prevent breaches or threatened breaches, without posting any bond or giving any other undertaking.

 

Each Party agrees that
it shall take all actions necessary to perform all its obligations under this Agreement. If any Party fails to perform any of its
obligations hereunder, such Party shall immediately perform such obligations, including its obligations to consummate the Transaction
contemplated herein.

 

11.12           No
Waiver. Neither any failure nor any delay by any Party in exercising any right, power, or privilege under this Agreement or
any of the documents referred to in this Agreement will operate as a waiver of such right, power, or privilege, and no single or
partial exercise of any such right, power, or privilege will preclude any other or further exercise of such right, power, or privilege
or the exercise of any other right, power, or privilege. To the maximum extent permitted by applicable Law, (a) no claim or
right arising out of this Agreement or any of the documents referred to in this Agreement can be waived by a Party, in whole or
in part, unless made in a writing signed by such Party, (b) a waiver given by a Party will only be applicable to the specific instance
for which it is given, and (c) no notice to or demand on a Party will (i) waive or otherwise affect any obligation of
that Party or (ii) affect the right of the Party giving such notice or demand to take further action without notice or demand
as provided in this Agreement or the documents referred to in this Agreement.

 

11.13           Notices.
All notices and other communications required or permitted by this Agreement shall be in writing and will be effective, and any
applicable time period shall commence, when (a) delivered to the following address by hand or by a nationally recognized overnight
courier service (costs prepaid) addressed to the following address or (b) transmitted electronically to the following facsimile
numbers or e-mail addresses, in each case marked to the attention of the Person (by name or title) designated below (or to such
other address, facsimile number, e-mail address, or Person as a Party may designate by notice to the other Party):

 

	The Investor:	 	 
	 	 	 
	 	Address:	 	 
	 	Attention:	 	Tuo
                                         Su
	 	E-mail:	 	 
	 	 	 	 
	The Company:	 	 
	 	 	 
	 	Address:	 	 
	 	Attention:	 	Frank
                                         Zhigang Zhao
	 	E-mail:	 	zhigangzhao@ccjmu.com

 

11.14           Severability.
If any provision of this Agreement is held invalid or unenforceable by any court of competent jurisdiction, the other provisions
of this Agreement will remain in full force and effect.  Any provision of this Agreement held invalid or unenforceable only
in part or degree will remain in full force and effect to the extent not held invalid or unenforceable.

 

     

     

    

 

11.15      Time
of Essence. With regard to all dates and time periods set forth or referred to in this Agreement, time is of the essence.

 

11.16      Counterparts
and Electronic Signatures.

 

(a)       This
Agreement and other documents to be delivered pursuant to this Agreement may be executed in one or more counterparts, each of which
will be deemed to be an original copy and all of which, when taken together, will be deemed to constitute one and the same agreement
or document, and will be effective when counterparts have been signed by each of the Parties and delivered to the other Party.

 

(b)       A
manual signature on this Agreement or other documents to be delivered pursuant to this Agreement, an image of which shall have
been transmitted electronically, will constitute an original signature for all purposes. The delivery of copies of this Agreement
or other documents to be delivered pursuant to this Agreement, including executed signature pages where required, by electronic
transmission will constitute effective delivery of this Agreement or such other document for all purposes.

 

[Signature Pages Follow]

 

     

     

    

 

In Witness Whereof, the Parties have executed this Share Purchase Agreement as of the date first written above. 

 

	 	
        THE COMPANY: 

         

        Mercurity Fintech Holding Inc.

	 	 
	 	 
	 	 	/s/ Hua Zhou
	 	Name: 	Hua Zhou
	 	Title: 	Chairperson of the Board of Directors, Chief Executive Officer
	 	 
	 	 

 

     

     

    

 

In Witness Whereof, the Parties have
executed this Share Purchase Agreement as of the date first written above.

 

	 	
        THE INVESTOR: 

         

        Universal Hunter (BVI) Limited

	 	 
	 	 
	 	 	/s/ Su Tuo
	 	
        Name:

        Title:
	
        SU TUO

        Director

 

     

     

    

 

SCHEDULE A Closing and Payment
Schedule 

 

	Closing	Cash Consideration to be Paid by the Investor to the Company	Number of Shares to be Issued by the Company to the Investor
	Closing I	US$300,000	90,000,000
	Closing II	US$700,000	210,000,000
	Total	US$1,000,000	300,000,000

 

     

     

    

 

SCHEDULE B Capitalization of the
Company 

 

	 	 	Number of Ordinary Shares 	 
	 	 	 	 
	Number of issued and outstanding ordinary shares at the signing of this Agreement and immediately prior to the Closing	 	2,870,659,129	 
	 	 	 	 
	Number of ordinary shares to be issued at the Closing I	 	90,000,000	 
	 	 	 	 
	Number of ordinary shares to be issued at the Closing II	 	210,000,000	 
	
         

        Outstanding options as of the date
        of this Agreement and at the Closing
	 	49,403,340Exhibit 4.19

 

MASTER
SOFTWARE DEVELOPMENT AGREEMENT

 

This Master Software Development Agreement
(the “Agreement”), dated as of May 28, 2018 (the “Effective Date”), is by and between Unicorn
Investment Limited, a BVI company (“Unicorn”) with registered office located at Trinity Chambers PO BOX 4301
Road Town, Tortola, BVI (”Developer”), and BGA FOUNDATION LTD, a Public company limited by Guarantee (“BGA”)
with registered office located at 9 TEMASEK BOULEVARD 04-02 SUNTEC TOWER TWO, SINGAPORE (”Customer”).

 

WHEREAS, Developer is engaged in the business
of providing software development and related services and work product; and

 

WHEREAS, Customer desires to retain Developer
to provide the software development and related services and work product described herein from time to time in separately executed
Statements of Work, and Developer desires to provide the same to Customer, each on the terms and conditions set forth herein.

 

NOW, THEREFORE, in consideration of the
mutual covenants, terms, and conditions set forth herein, and for other good and valuable consideration, the receipt and sufficiency
of which are hereby acknowledged, Customer and Developer agree as follows:

 

1.  Definitions. For purposes
of this Agreement, the following terms have the following meanings:

 

    “
Acceptance” has the meaning set forth in Section 5.8.

 

    “Acceptance
Tests” means such tests as may be conducted in accordance with Section 5.4 and the applicable Statement of Work to determine
whether any Software Deliverable meets the requirements of this Agreement and the Specifications and Documentation therefor.

 

    “Action”
means any claim, action, cause of action, demand, lawsuit, arbitration, inquiry, audit, notice of violation, proceeding, litigation,
citation, summons, subpoena, or investigation of any nature, civil, criminal, administrative, regulatory, or other, whether at
law, in equity, or otherwise.

 

    “Affiliate”
of a Person means any other Person that directly or indirectly, through one or more intermediaries, controls, is controlled by,
or is under common control with, such Person. [The term “control” (including the terms “controlled by”
and “under common control with”) means the direct or indirect power to direct or cause the direction of the management
and policies of a Person, whether through [the ownership of voting securities, by contract, or otherwise/ownership of more than10%
of the voting securities of a Person].]

 

    “Agreement”
has the meaning set forth in the preamble.

 

    “Aggregate
Software” means the Software, as a whole, to be developed or otherwise provided under a particular Statement of Work.
For avoidance of doubt, if a Statement of Work provides for a single Software Deliverable, such Software Deliverable shall also
constitute Aggregate Software.

 

    “Allegedly
Infringing Materials” has the meaning set forth in Section 12.3(a)(ii).

 

    

     

    

 

    “Approved
Open Source Components” means Open Source Components that Customer has approved to be included in or used in connection
with any Software developed or provided hereunder and which are specifically identified in Exhibit C or the Statement of
Work for such Software.]

 

    “Approved
Third-Party Materials” means the Third-Party Materials that Customer has approved to be included in or for use in connection
with any Software developed or provided hereunder and which are specifically identified in Exhibit C or the Statement of
Work for such Software.

 

    “Background
Technology” means all Software, data, know-how, ideas, methodologies, specifications, and other technology in which Developer
owns such Intellectual Property Rights as are necessary for Developer to grant the rights and licenses set forth in Section 10.1,
and for Customer (including its licensees, successors, and assigns) to exercise such rights and licenses, without violating any
right of any Third Party or any Law, or incurring any payment obligation to any Third Party, and that: (a) are identified as background
technology in any Statement of Work; and (b) were or are developed or otherwise acquired by Developer prior to Effective Date,
with respect to the Initial Statement of Work, or the date of Customer’s request for additional Services, with respect to
any other Statement of Work.]

 

    “Business
Requirements Specification” means the initial specification setting forth Customer’s business requirements regarding
the features and functionality of the Software under the Initial Statement of Work and attached as Exhibit A hereto.]

 

    “Change”
has the meaning set forth in Section 3.4.

 

    “Change
Agreement” has the meaning set forth in Section 3.4(b).

 

    “Change
Proposal” has the meaning set forth in Section 3.4(a).

 

    “Change
Request” has the meaning set forth in Section 3.4.

 

    “Confidential
Information” has the meaning set forth in Section 8.1.

 

    “CPI”
has the meaning set forth in Section 7.8(c)(ii)

 

    “Customer”
has the meaning set forth in the preamble.

 

    “Customer
Materials” means all materials and information, including documents, data, know-how, ideas, methodologies, specifications,
software, content, and technology, in any form or media, directly or indirectly provided or made available to Developer by or on
behalf of Customer in connection with this Agreement, whether or not the same: (a) are owned by Customer, a Third Party, or in
the public domain; or (b) qualify for or are protected by any Intellectual Property Rights.

 

    “Customer
Resources” has the meaning set forth in Section 4.1(b).

 

    “Deliverables”
means all Software Deliverables and all other documents, work product, and other materials that Developer is required to [or otherwise
does] provide to Customer [or its designee] under this Agreement and otherwise in connection with any Services, including any and
all items specifically identified as Deliverables in any Statement of Work.

 

    “Developer”
has the meaning set forth in the preamble.

 

    “Developer
Personnel” means all employees of Developer or any Permitted Subcontractors involved in the performance of Services or
providing Work Product hereunder.

 

    “Developer’s
Proposal” means the developer’s proposal submitted in response to the RFP.]

 

    

     

    

 

    “Disclosing
Party” has the meaning set forth in Section 8.1.

 

    “Documentation”
means all generally available documentation relating to the Software, including all user manuals, operating manuals, and other
instructions, specifications, documents, and materials, in any form or media, that describe any component, feature, requirement,
or other aspect of the Software, including any functionality, testing, operation, or use thereof.

 

    “Effective
Date” has the meaning set forth in the preamble.

 

    “Fees”
has the meaning set forth in Section 7.1.

 

    “Force
Majeure” has the meaning set forth in Section 15.11.

 

    “Functional
Specification” means, with respect to any Software, the document setting forth Customer’s requirements with respect
to such Software’s features and functions, and included in the Statement of Work for such Software.

 

    “Harmful
Code” means any: (a) virus, trojan horse, worm, backdoor, or other software or hardware devices the effect of which is
to permit unauthorized access to, or to disable, erase, or otherwise harm, any computer, systems, or software; or (b) time bomb,
drop-dead device, or other software or hardware device designed to disable a computer program automatically with the passage of
time or under the positive control of any Person, or otherwise deprive Customer of its lawful right to use the Software.

 

    “Implementation
Plan” means the schedule included in each Statement of Work setting forth the sequence of events for the performance
of Services under such Statement of Work, including the Milestones and Milestone Dates thereunder.

 

    “Initial
Statement of Work” means the Statement of Work for the initial Software development and related Services hereunder [attached
as Exhibit A hereto/as developed by Developer and agreed by the parties as set forth in Section 3.2].

 

    “Initial
Term” has the meaning set forth in Section 14.1.]

 

    “Intellectual
Property Rights” means any and all registered and unregistered rights granted, applied for, or otherwise now or hereafter
in existence under or related to any patent, copyright, trademark, trade secret, database protection, or other intellectual property
rights laws, and all similar or equivalent rights or forms of protection, in any part of the world.

 

    “Intended
Users” means the category(ies) of users that are intended to use Software or particular features or functions thereof,
as described in the Specifications for such Software.

 

    “Key
Personnel” means any Developer Personnel identified as key personnel in this Agreement or, with respect to any Statement
of Work, such Statement of Work.

 

    “Law”
means any statute, law, ordinance, regulation, rule, code, order, constitution, treaty, common law, judgment, decree, or other
requirement of any federal, state, local, or foreign government or political subdivision thereof, or any arbitrator, court, or
tribunal of competent jurisdiction.

 

    “Losses”
means all losses, damages, deficiencies, claims, actions, judgments, settlements, interest, awards, penalties, fines, costs, or
expenses of whatever kind, including reasonable attorneys’ fees and the costs of enforcing any right to indemnification hereunder
and the cost of pursuing any insurance providers.

 

    

     

    

 

    “Milestone”
means an event or task described in the Implementation Plan under any Statement of Work that must be completed by the corresponding
Milestone Date set forth therein.

 

    “Milestone
Date” means the date by which a particular Milestone must be completed as set forth in the Implementation Plan under
any Statement of Work.

 

    “Non-Conformity”
means any failure of any (a) Software or Documentation to conform to the requirements of this Agreement (including any applicable
Statement of Work); or (b) Software to conform to the requirements of this Agreement or the Specifications or Documentation therefor.

 

    “Open
Source Components” means any software component that is subject to any open source copyright license agreement, including
software available under the GNU Affero General Public License (AGPL), GNU General Public License (GPL), GNU Lesser General Public
License (LGPL), Mozilla Public License (MPL), Apache License, BSD licenses, or any other license that is approved by the Open Source
Initiative.

 

    “Open
Source License” has the meaning set forth in Section 2.6.]

 

    “Operating
Environment” means, collectively, the Customer platform and environment on, in, or under which Software is intended to
be installed and operate, as set forth in the Statement of Work for such Software, including such structural, functional, and other
features, conditions, and components as hardware, operating software, and system architecture and configuration.

 

    “Permitted
Subcontractor” has the meaning set forth in Section 2.10.

 

    “Person”
means an individual, corporation, partnership, joint venture, limited liability entity, governmental authority, unincorporated
organization, trust, association, or other entity.

 

    “Receiving
Party” has the meaning set forth in Section 8.1.

 

    “Reimbursable
Expenses” has the meaning set forth in Section 7.2.

 

     “Renewal
Term” has the meaning set forth in Section 14.2.]

 

    “Representatives”
means a party’s [and its Affiliates’] employees, officers, directors, consultants, legal advisors, and Permitted Subcontractors[,
and with respect to Customer, its independent contractors and service providers].

 

    “RFP”
means Customer’s request for proposal, dated as of June 1, 2018, included in Exhibit A to this Agreement].]

 

    “Services”
means any of the services Developer provides under this Agreement or any Statement of Work, as more fully described in this Agreement
or such Statement of Work.

 

    “Site”
means the physical location designated by Customer in, or in accordance with, this Agreement or any Statement of Work for delivery
and/or installation of any Software.

 

    “Software”
means the computer program(s), including programming tools, scripts, and routines, the Developer develops or otherwise provides
under this Agreement, as described more fully in each Statement of Work[, including all updates, upgrades, new versions, new releases,
enhancements, improvements, and other modifications made or provided pursuant to the Support Services]. As context dictates, Software
may refer to one or more Software Deliverables or Aggregate Software.

 

    

     

    

 

    “Software
Deliverable” means any Software, together with the Documentation therefor, required to be delivered as a Milestone as
set forth in the Implementation Plan for such Software.

 

    “Source
Code” means the human readable source code of the Software to which it relates, in the programming language in which
such Software was written, together with all related flow charts, code, and technical documentation, including a description of
the procedure for generating object code, all of a level sufficient to enable a programmer reasonably fluent in such programming
language to understand, build, operate, support, maintain, and develop modifications, upgrades, updates, adaptations, enhancements,
new versions, and other derivative works and improvements of, and to develop computer programs compatible with, the Software.

 

    “Specifications”
means, for any Software, the specifications collectively set forth in the [Business Requirements Specification,] Functional Specification[,]
and Technical Specification therefor[, together with any other specifications set forth in the RFP or Developer’s Proposal,
if any, for such Software, or elsewhere in the relevant Statement of Work].

 

   “Statement
of Work” means any statement of work entered into by the parties and attached as an exhibit to this Agreement. [The Initial
Statement of Work is attached as Exhibit A, and subsequent Statements of Work shall be sequentially identified and attached
as Exhibit A-1, A-2, A-3, etc.]

 

    “Support
Commencement Date” means, with respect to any Software, the date on which the Warranty Period for such Software expires
or such other date as may be set forth in Exhibit E or the Statement of Work for such Software.

 

    “Support
Fees” means the fees, if any, payable by Customer for Support Services as set forth in the [Fee/ Support Services] Exhibit
or any Statement of Work.

 

    “Support
Services” means the Software maintenance, hosting and support services the Developer is required to provide under this
Agreement as set forth in Exhibit E.

 

    “Technical
Specification” means, with respect to any Software, the document setting forth the technical specifications for such
Software and included in the Statement of Work for such Software.

 

    “Term”
has the meaning set forth in [Section 14.1/Section 14.2].

 

    “Testing
Period” has the meaning set forth in Section 5.4(b).

 

    “Third
Party” means any Person other than Customer or Developer. For purposes of this Agreement, the parties’ Affiliates
are Third Parties.

 

    “Third-Party
Materials” means any materials and information, including documents, data, know-how, ideas, methodologies, specifications,
software, content, and technology, in any form or media, in which any Person other than Customer or Developer owns any Intellectual
Property Right, but specifically excluding Open Source Components.

 

    “Warranty
Period” means, for any Software, the twelve (12)] /month] period commencing (a) in the case of Aggregate Software, Customer’s
Acceptance thereof; and (b) in the case of any updates, upgrades, new versions, new releases, enhancements, and other modifications
to previously-Accepted Aggregate Software, including those made pursuant to the Support Services, Customer’s receipt thereof.

 

    

     

    

 

    “Work
Product” means all Software, Documentation, Specifications, and other documents, work product, and materials related
thereto, that Developer provides to Customer [or its designee] hereunder, together with all ideas, concepts, processes, and methodologies
developed in connection therewith, whether or not embodied therein [other than materials expressly identified in a[n exhibit to
this Agreement or a] Statement of Work as [Background Technology [or/,]]Approved Third-Party Materials[, or Approved Open Source
Components]].

 

2.  Software Development Services.

 

    2.1 Engagement
of Developer. Customer hereby engages Developer, and Developer hereby accepts such engagement, to develop Software and provide
Services related thereto as described herein or otherwise requested by Customer from time to time and described in Statements of
Work therefor, all on the terms and conditions set forth in this Agreement and such Statements of Work.

 

    2.2 Performance
of Services. Developer shall provide all Services and Work Product hereunder in a timely, professional, and workmanlike manner
and in accordance with the terms, conditions, and Specifications set forth in this Agreement and each Statement of Work.

 

    2.3 Software
Development. Developer shall design, develop, create, test, deliver, install, configure, integrate, customize, and otherwise
provide and make fully operational Software as described in each Statement of Work on a timely and professional basis in accordance
with all terms, conditions, and Specifications set forth in this Agreement and such Statement of Work. Where the applicable Statement
of Work requires or permits delivery of Software in two or more phases, Developer shall also provide Customer with integrated Documentation
for the Aggregate Software upon its delivery. Developer shall ensure all Software complies with the Specifications therefor. [Except
to the extent expressly provided otherwise in the Statement of Work for any Software, ] Developer shall provide all Software to
Customer in both object code and Source Code form.

 

    2.4 Documentation.
Prior to or concurrently with the delivery of any Software hereunder, or by such earlier date as may be specified in the Implementation
Plan for such Software, Developer shall provide Customer with complete and accurate Documentation for such Software. Where the
applicable Statement of Work requires or permits delivery of Software in two or more phases, Developer shall also provide Customer
with integrated Documentation for the Aggregate Software upon its delivery.

 

(a)  Adequacy of
Documentation. All Documentation shall include all such information as may be reasonably necessary for the effective installation,
testing, use, support, and maintenance of the applicable Software by the Intended User, including the effective configuration,
integration, and systems administration of the Software and performance of all other functions set forth in the Specifications.

 

(b)  Documentation
Specifications. Developer shall provide all Documentation in both hard copy and electronic form, in such formats and media
as are set forth in Exhibit A or the relevant Statement of Work, or as Customer may otherwise [reasonably] request [in writing].

 

(c)  Third-Party
Documentation. Other than Documentation for Approved Third-Party Materials[ and Approved Open Source Components], no Documentation
shall consist of or include Third-Party Materials. To the extent Documentation consists of or includes Third-Party Materials, Developer
shall secure, at its sole cost and expense, all rights, licenses, consents, approvals, and authorizations specified in Section
10.3 with respect to Approved Third-Party Materials.

 

    

     

    

 

    2.5  Third-Party
Materials.

 

(a)  Developer shall
not include in any Software, and operation of all Software in accordance with its Specifications and Documentation shall not require,
any Third-Party Materials, other than Approved Third-Party Materials specifically described in Exhibit C or the Statement
of Work for such Software and licensed to Customer in accordance with Section 10.3.

 

(b)  Except as provided
otherwise in Exhibit C or the applicable Statement of Work, Developer shall secure, at its sole cost and expense, all necessary
rights, licenses, consents, approvals, and authorizations necessary for Customer to use, perpetually and throughout the universe,
all Approved Third-Party Materials as incorporated in or otherwise used in conjunction with Software as specified in the applicable
Statement of Work or elsewhere in this Agreement.

   

    2.6  Open
Source Components. Developer shall not include in any Software, and operation of all Software in accordance with its Specifications
and Documentation shall not require the use of, any Open Source Components[, other than Approved Open Source Components specifically
described in Exhibit C or the Statement of Work for such Software, and for which the relevant open source license(s) (each,
an “Open Source License”) are included in Exhibit C or such Statement of Work. Developer shall provide
Customer with a complete, machine-readable copy of the Source Code for Approved Open Source Components in accordance with the terms
of the Open Source License(s) therefor at no cost to the Customer].

 

    2.7  Relationship
Managers. Throughout the Term of this Agreement, each party shall maintain within its organization a relationship manager to
serve as such party’s primary point of contact for day-to-day communications, consultation, and decision making regarding
this Agreement. Each party shall ensure its relationship manager has the requisite authority and skill to perform in such capacity.
The parties’ initial relationship managers are stated in Exhibit A. Each party shall use reasonable efforts to maintain the
same relationship manager in place throughout the Term. If either party’s relationship manager ceases to be employed by such
party[ or such party otherwise wishes to replace its relationship manager], such party shall promptly name a new relationship manager
by written notice to the other party.

 

    2.8  Developer
Personnel. Developer is solely responsible for all Developer Personnel and for the payment of their compensation, including,
if applicable, withholding of income taxes, and the payment and withholding of social security and other payroll taxes, unemployment
insurance, workers’ compensation insurance, and disability benefits. Prior to any Developer Personnel performing any Services
hereunder, Developer shall:

 

(a)  ensure that Developer
Personnel have the legal right to work in the United States, China and Hongkong;

 

(b)  require such Developer
Personnel to execute written agreements, in form and substance [reasonably] acceptable to Customer that bind such Developer Personnel
to confidentiality provisions that are at least as protective of Customer’s information (including all Confidential Information)
as those contained in this Agreement and Intellectual Property Rights provisions that grant Customer rights in the Work Product
consistent with the provisions of Section 9.1, and, upon Customer’s request, provide Customer with [a copy of] each such
executed agreement;

 

    

     

    

 

(c)  at its sole cost
and expense, conduct background checks on such Developer Personnel, which background checks shall comprise, at a minimum, a review
of credit history, references, and criminal record, in accordance with applicable Law. Provider shall ensure that no Person who
has been convicted of a felony or any misdemeanor involving, in any way, theft, fraud, bribery, or the violation of any securities
law provides any Services or has access to any Confidential Information of Customer; and

 

(d)  upon the [reasonable]
written request of Customer, promptly replace any Developer Personnel.

 

Developer shall, and shall ensure
that all Developer Personnel, comply with all rules, regulations, and policies of Customer that are communicated to Developer in
writing, including security procedures concerning systems and data and remote access thereto, building security procedures[, including
the restriction of access by Customer to certain areas of its premises or systems], and general health and safety practices and
procedures.

 

    2.9  Developer
Project Managers. Upon the execution of each Statement of Work Developer shall appoint, and throughout the term of such Statement
of Work Developer shall maintain, a Developer employee [[reasonably] acceptable to Customer] to serve as Developer’s project
manager (each, a “Developer Project Manager”) under such Statement of Work.

 

(a)  Each Developer
Project Manager shall:

 

(i)  have the requisite
authority and necessary skill, experience, and qualifications to perform in such capacity;

 

(ii)  be responsible
for overall management and supervision of Developer’s performance under such Statement of Work; and

 

(iii)  be Customer’s
primary point of contact for communications with respect to such Statement of Work, including with respect to giving and receiving
all day-to-day approvals and consents thereunder.

 

(b)  The Developer
Project Manager shall attend all regularly scheduled meetings as set forth in the Implementation Plan and all additional meetings
scheduled on at least 24 hours prior notice, and otherwise shall be available as set forth in the Statement of Work.

 

(c)  Developer shall
maintain the same Developer Project Manager throughout the term of such Statement of Work, unless:

 

(i)  Customer [reasonably]
requests in writing the removal of the Developer Project Manager;

 

(ii)  Customer consents
in writing to any removal [reasonably] requested by Developer in writing;

 

(iii)  the Developer
Project Manager ceases to be employed by Developer, whether by resignation, involuntary termination, or otherwise.]

 

(d)  Developer shall
promptly replace the Developer Project Manager under any Statement of Work on the occurrence of any event set forth in Section
2.9(c). [Such replacement shall be subject to Customer’s [reasonable] prior written approval.]

 

    

     

    

 

    2.10  Subcontractors.
Developer shall not, without the prior written approval of Customer[, which consent [shall not be unreasonably withheld [or delayed]/may
be given or withheld in Customer’s sole discretion],] engage any Third Party to perform Services (including to create any
Work Product) hereunder. Customer’s approval of any such Third Party (each approved Third Party, a “Permitted Subcontractor”)
shall not relieve Developer of its representations, warranties, or obligations under the Agreement. Without limiting the foregoing,
Developer shall:

 

(a)  be responsible
and liable for the acts and omissions of each such Permitted Subcontractor (including such Permitted Subcontractor’s employees
who, to the extent providing Services or creating Work Product, shall be deemed Developer Personnel) to the same extent as if such
acts or omissions were by Developer or its employees;

 

(b)  [name Customer
a third-party beneficiary under Developer’s agreement with each Permitted Subcontractor with respect to the Services and
Work Product;]

 

(c)  be responsible
for all fees and expenses payable to, by, or on behalf of each Permitted Subcontractor in connection with this Agreement, including,
if applicable, withholding of income taxes, and the payment and withholding of social security and other payroll taxes, unemployment
insurance, workers’ compensation insurance, and disability benefits; and

 

(d)  prior to the provision
of Services or creation of Work Product by any Permitted Subcontractor:

 

(i)  obtain from such
Permitted Subcontractor confidentiality, work-for-hire, and intellectual property rights assignment agreements, in form and substance
acceptable to Customer, giving Customer rights consistent with those set forth in Section 9.1 and Section 8, and, upon request,
provide Customer with a fully-executed copy of each such agreement; and

 

(ii)  with respect
to all Permitted Subcontractor employees providing Services or Work Product, comply with its obligations under Section 2.8.

 

    2.11  Time
of the Essence. Developer acknowledges that time is of the essence with respect to Developer’s obligations hereunder
and agrees that prompt and timely performance of all such obligations in accordance with this Agreement and each Statement of Work
(including the Implementation Plan and all Milestone Dates included therein) is strictly required.

 

3.  Statements of Work.
Developer shall provide Services and Work Product pursuant to Statements of Work entered into as set forth herein. No Statement
of Work shall be effective unless signed by duly authorized representatives of both parties. The term of each Statement of Work
shall be as set forth therein or, if no term is specified, shall commence on the parties’ full execution thereof and terminate
when the parties have fully performed their obligations thereunder. Unless a Statement of Work expressly states otherwise, Customer
shall have the right to terminate such Statement of Work as set forth in Section 14.3.

 

    3.1  Statement
of Work Requirements. Each Statement of Work shall be [substantially] in the form used in Exhibit A attached hereto,
and shall include the following:

 

(a)  names and contact
information for the Customer Project Manager, Developer Project Manager, and, if relevant, Key Personnel of Developer under such
Statement of Work;

 

(b)  a detailed description
of the Services to be provided thereunder;

 

(c)  a detailed description
of the Software and other Work Product to be developed or otherwise provided under such Statement of Work, including a:

 

    

     

    

 

(i)  Functional Specification;

 

(ii)  Technical Specification;
and

 

(iii)  description
of the Documentation to be provided;

 

(d)  an Implementation
Plan, including all Milestones, the corresponding Milestone Dates, and the parties’ respective responsibilities therefor;

 

(e)  Fees payable under
such Statement of Work, the manner in which such Fees shall be calculated, the due dates for payment thereof, including any Milestones
on which any such Fees are conditioned, and such other information as the parties deem necessary;

 

(f)  disclosure of
all Approved Third-Party Materials[ and Approved Open Source Components in each case] accompanied by such related documents as
may be required by this Agreement with respect thereto; and

 

(g)  a detailed description
of all Customer Resources required under such Statement of Work.

 

    3.2  Initial
Statement of Work. The Initial Statement of Work [is attached as Exhibit A hereto/will be developed and agreed by the
parties as set forth in this Section 3.2].

 

(a)  [Commencing on
the Effective Date, Developer shall perform the consulting and related Services set forth in the Initial Statement of Work for
purposes of creating and providing to Customer Developer’s proposed Statement of Work for developing Software that meets
all criteria set forth in the Business Requirements Specification.

 

(b)  Developer shall
deliver its proposed Statement of Work to Customer on or before the due date therefor as set forth in the Initial Statement of
Work, whereupon Customer shall have the period set forth in the Initial Statement of Work to review and, in its discretion, approve
or raise objections to the Developer’s proposed Statement of Work. If Customer raises any such objections, the parties shall
negotiate in good faith to amend the proposal, provided that:

 

(i)  to the extent
the proposal does not comply with the requirements of this Agreement and the Business Requirements Specification, it shall be amended
to so comply; and

 

(ii)  either party
may terminate negotiations[ and this Agreement] if the parties fail to agree on the proposed Statement of Work prior to the date
specified in the Initial Statement of Work.

 

(c)  Upon the parties’
agreement to the Initial Statement of Work, each party shall cause the same to be signed by its duly authorized representative.
Upon its mutual execution, the Initial Statement of Work shall be attached as Exhibit A-1 and form a part of this Agreement
and the proposed Statement of Work shall be attached as Exhibit A-2 and form a part of this Agreement.

 

(d)  If this Agreement
is terminated by either party pursuant to Section 3.2(b)(ii):

 

(i)  Customer’s
rights to the Initial Statement of Work and all drafts thereof and proposals relating thereto shall be as set forth in Exhibit
A or the Initial Statement of Work; and

 

(ii)  Developer shall
be compensated as set forth in Exhibit A or the Initial Statement of Work.]

 

    

     

    

 

    3.3  Additional
Statements of Work. [Promptly/Within 3 days] following receipt of Customer’s request for [additional] Software development
or other Services, Developer shall provide Customer with a proposal [[substantially] in the form of, and containing all information
specified in, the attached Exhibit A]. Upon the parties’ agreement with respect to the terms of such proposal, all
such terms shall be incorporated in a Statement of Work and each party shall cause the same to be signed by its duly authorized
representative. Each fully executed Statement of Work shall be attached as an Exhibit to, and by this reference incorporated in
and made a part of, this Agreement.

 

    3.4  Changes
to Statements of Work. Customer may at any time request in writing (each, a “Change Request”) changes to
any Statement of Work, including changes to the Services, Work Product, Implementation Plan, or any Specifications (each, a “Change”).
Upon Customer’s submission of a Change Request, the parties shall evaluate and implement all Changes in accordance with this
Section 3.4.

 

(a)  As soon as reasonably
practicable, and in any case within 3 days following receipt of a Change Request, Developer shall provide Customer with a written
proposal for implementing the requested Change (”Change Proposal”), setting forth:

 

(i)  a written description
of the proposed Changes to any Services, Work Product, or Deliverables;

 

(ii)  an amended Implementation
Plan reflecting: (A) the schedule for commencing and completing any additional or modified Services, Work Product, or Deliverables;
and (B) the effect of such Changes, if any, on completing any other Services or Work Product under the Statement of Work;

 

(iii)  any additional
Third-Party Materials, Open Source Components, and Customer Resources Developer deems necessary to carry out such Changes; and

 

(iv)  any increase
or decrease in Fees resulting from the proposed Changes, which increase or decrease shall reflect only the increase or decrease
in time and expenses Developer requires to carry out the Change.

 

(b)  Within 3 days
following Customer’s receipt of a Change Proposal, Customer shall by written notice to Developer, approve, reject, or propose
modifications to such Change Proposal. If Customer proposes modifications, Developer shall modify and re-deliver the Change Proposal
reflecting such modifications, or notify Customer of any disagreement therewith, in which event the parties shall negotiate in
good faith to resolve their disagreement. Upon Customer’s approval of the Change Proposal or the parties’ agreement
on all proposed modifications thereto, as the case may be, the parties shall execute a written agreement to the Change Proposal
(”Change Agreement”), which Change Agreement shall constitute an amendment to the Statement of Work to which
it relates; and

 

(c)  If the parties
fail to enter into a Change Agreement within 5 days following Customer’s response to a Change Proposal, Customer shall have
the right, in its discretion, to:

 

(i)  require Developer
to perform the Services under the Statement of Work without the Change;

 

(ii)  require Developer
to continue to negotiate a Change Agreement; or

 

    

     

    

 

(iii)  notwithstanding
any provision to the contrary in such Statement of Work, terminate the Statement of Work pursuant to Section 14.3(a)(iii).

 

    No Change
will be effective until the parties have executed a Change Agreement with respect thereto. Except as Customer may request in its
Change Request or otherwise in writing, Developer shall continue to perform its obligations in accordance with the Statement of
Work pending negotiation and execution of a Change Agreement. Developer shall [use its [commercially reasonable/best] efforts to]
limit any delays or Fee increases from any Change to those necessary to perform the Change in accordance with the applicable Change
Agreement. Each party shall be responsible for its own costs and expenses of preparing, evaluating, negotiating, and otherwise
processing any Change Request, Change Proposal, and Change Agreement.

 

4.  Customer Obligations.

 

    4.1  Customer
Resources and Cooperation. Customer shall be responsible, on a timely basis in accordance with each Statement of Work, including
the Implementation Plan and Milestone Dates set forth therein, for:

 

(a)  performing all
obligations identified as “Customer Responsibilities” in such Statement of Work;

 

(b)  providing the
Customer Materials and such other resources as may be specified in such Statement of Work (collectively, “Customer Resources”);

 

(c)  providing Developer
Personnel with such access to the Site[s] and Operating Environment as is necessary for Developer to perform its obligations on
a timely basis as set forth in such Statement of Work;

 

(d)  participating
with suitably qualified and authorized personnel in all meetings scheduled in, or in accordance with, such Statement of Work, and
such other meetings as may be scheduled on no less than [NUMBER IN WORDS] ([NUMBER]) days’ prior notice; and

 

(e)  providing all
consents, approvals, exception notices, and other communications specified in such Statement of Work or as otherwise may be required
under this Agreement.

 

    4.2  Customer
Project Managers.

 

(a)  Upon the execution
of each Statement of Work, Customer shall appoint, and throughout the term of such Statement of Work Customer shall maintain, a
Customer employee to serve as Customer’s project manager under such Statement of Work (each, a “Customer Project
Manager”). Each Customer Project Manager shall:

 

(i)  have the requisite
authority, and necessary skill, experience, and qualifications, to perform in such capacity;

 

(ii)  be responsible
for overall management and supervision of Customer’s performance under such Statement of Work; and

 

(iii)  be Developer’s
primary point of contact for communications with respect to such Statement of Work, including with respect to providing and receiving
all day-to-day approvals and consents thereunder.

 

    

     

    

 

(b)  Each Customer
Project Manager shall attend all regularly scheduled meetings as set forth in the Implementation Plan and additional meetings scheduled
on at least 24 hours prior notice, and otherwise shall be available as set forth in the Statement of Work.

 

    4.3  Effect
of Customer Delays. If, as a result of any failure by Customer to perform any of its obligations set forth in Section 4.1 on
a timely basis under any Statement of Work, Developer is unable to timely meet all or any remaining Milestones under such Statement
of Work, either at all or without incurring additional costs, Developer may extend such Milestone Dates for up to the length of
Customer’s delay [or, at Customer’s option, increase the related Fees solely to recover any such additional costs,]
in accordance with the following:

 

(a)  Developer shall
promptly notify Customer in writing, proposing a revised Implementation Plan reflecting new Milestone Dates for each affected Milestone,
which Milestone Dates may be extended by no longer than the length of Customer’s delay and, if Developer is able to meet
the original Milestone Dates by incurring additional costs:

 

(i)  for fixed-fee
Services, its proposed Fee increase for meeting the original Milestone Dates; or

 

(ii)  for time-and-materials
Services, the estimated costs of overtime Customer would incur for Developer to meet the original Milestone Dates.

 

(b)  Upon receipt of
any notice given under Section 4.3(a), subject to Section 4.3(c), Customer shall promptly notify Developer in writing of its election.
Customer’s failure to notify Developer within 3 days after such receipt shall be deemed an acceptance of the new Milestone
Dates and rejection of all Fee increases.

 

(c)  If Customer disputes
Developer’s right to extend Milestone Dates or increase Fees, or the extent of any proposed extension or increase, Customer
shall promptly notify Developer and the parties shall negotiate in good faith to resolve the dispute.

 

    Notwithstanding
anything contained in this Section 4.3 or otherwise in this Agreement, Developer shall use its [commercially reasonable/best] efforts
to meet the Milestone Dates specified in the Statement of Work without any extension or Fee increase. Customer shall not be deemed
in breach of this Agreement for failure to perform its obligations on a timely basis, and the provisions of this Section 4.3 set
forth Developer’s sole and exclusive remedy, and Customer’s sole and exclusive liability, for Customer’s failure
to perform its obligations under this Section 4.

 

5.  Delivery, Installation,
and Acceptance.

 

    5.1  [Pre-Delivery
Testing by Developer. Before delivering and installing any Software Deliverable, Developer shall:

 

(a)  test the Software
component of such Software Deliverable to confirm that it is fully operable, meets all applicable Specifications, and will function
in accordance with the Specifications and Documentation when properly installed in the Operating Environment;

 

(b)  scan such Software
Deliverable using the most up-to-date scanning software and definitions to confirm it is free of Harmful Code;

 

    

     

    

 

(c)  remedy any Non-Conformity
or Harmful Code identified and retest and rescan the Software Deliverable; and

 

(d)  prepare, test,
and, as necessary, revise the Documentation component of the Software Deliverable to confirm it is complete and accurate and conforms
to all requirements of this Agreement.

 

Customer shall have the right
to be present for all pre-installation testing. Developer shall give Customer at least three (3) days’ prior notice of all
such testing.]

 

    5.2  Delivery.
Developer shall deliver each Deliverable[, and install all Software,] on or prior to the Milestone Date therefor in accordance
with the delivery criteria set forth in Exhibit D or such other criteria as may be set forth for such Deliverable in the
Statement of Work therefor. Developer shall deliver each Software Deliverable, including complete Documentation in compliance with
Section 2.4 and, except to the extent the Statement of Work specifies otherwise, the Source Code therefor. No Software Deliverable
shall be deemed to have been delivered or installed unless it complies with the preceding sentence.

 

    5.3  Site
Preparation. [Customer/Developer] shall be responsible for ensuring the relevant Operating Environment is set up and in working
order to allow Developer to deliver [and install] each Software Deliverable on or prior to the Milestone Date therefor. Developer
shall provide Customer with such notice as is specified in Exhibit D, or such other notice as is specified for such Software
Deliverable in the Statement of Work therefor, prior to delivery of each such Software Deliverable, to give Customer sufficient
time to prepare for Developer’s delivery [and installation] of the Software Deliverable. If Customer is responsible for Site
preparation, Developer shall provide such assistance as Customer [reasonably] requests to complete such preparation on a timely
basis.

 

    5.4  Acceptance
Testing.

 

(a)  Upon delivery
or, if Developer is responsible for installation, installation of each Software Deliverable, Acceptance Tests shall be conducted
as set forth in this Section 5.4 to ensure the Software Deliverable, including all Software and Documentation, conforms to the
requirements of this Agreement, including the applicable Specifications and, in the case of the Software, the Documentation.

 

(b)  All Acceptance
Tests shall take place at the designated Site(s) in the Operating Environment described in the Statement of Work for the Software
Deliverable, commence on the business day following delivery or installation, as applicable, of such Software Deliverable, and
be conducted diligently for up to [thirty (30)] days[, or such other period as may be set forth in the relevant Statement of Work]
(”Testing Period”). Acceptance Tests shall be conducted by the party responsible therefor as set forth in the
applicable Statement of Work or, if the Statement of Work does not specify, [Customer/Developer], provided that:

 

(i)  for Acceptance
Tests conducted by Customer, if requested by Customer, Developer shall make suitable Developer Personnel available to observe or
participate in such Acceptance Tests; and

 

(ii)  for Acceptance
Tests conducted by Developer, Customer shall have the right to observe or participate in all or any part of such Acceptance Tests.

 

    

     

    

 

[Developer’s performance
of, participation in, and observation of Acceptance Testing shall be at Developer’s sole cost and expense.]

 

(c)  Upon delivery
[and installation] of the Aggregate Software under any Statement of Work, additional Acceptance Tests shall be performed on the
Aggregate Software as a whole to ensure full operability, integration, and compatibility among all elements of the Aggregate Software
(”Integration Testing”). Integration Testing shall be subject to all procedural and other terms and conditions
set forth in Section 5. [The scope of Integration Testing on any previously-Accepted Software Deliverable shall be limited to ensuring
full operability, integration, and compatibility and Customer shall not have the right to condition its acceptance thereof on Developer’s
correction of any nonconformity that could have been, but was not, identified by Customer during initial testing of such Software
Deliverable.]

 

(d)  [Customer may
suspend Acceptance Tests and the corresponding Testing Period by written notice to Developer if Customer discovers a [material]
Non-Conformity in the tested Software Deliverable or part or feature thereof. In such event, Developer shall immediately, and in
any case within 1 days, correct such Non-Conformity, whereupon the Acceptance Tests and Testing Period shall resume for the balance
of Testing Period.]

 

    5.5  Notices of Completion,
Non-Conformities, and Acceptance. [Within two (2) days following/Immediately upon] the completion of any Acceptance Tests,
including any Integration Testing, the party responsible for conducting the tests shall prepare and provide to the other party
written notice of the completion of the tests. Such notice shall include a report describing in reasonable detail the tests conducted
and the results thereof, including any uncorrected Non-Conformity in the tested Software Deliverable(s).

 

(a)  If such notice
is provided by either party and identifies any Non-Conformities, the parties’ rights, remedies, and obligations will be as
set forth in Section 5.6 and Section 5.7.

 

(b)  If such notice
is provided by Customer and identifies no Non-Conformities, such notice shall constitute Customer’s Acceptance of such Software
Deliverable or Aggregate Software.

 

(c)  If such notice
is provided by Developer and identifies no Non-Conformities, Customer shall have two ([2]) days to [use such Software Deliverable
in the Operating Environment and determine, in the exercise of its [sole/reasonable] discretion, whether it is satisfied that such
Software Deliverable or Aggregate Software contains no Non-Conformities, on the completion of which Customer shall, as appropriate:

 

(i)  notify Developer
in writing of Non-Conformities Customer has observed in the Software Deliverable or, in the case of Integration Testing, Aggregate
Software, and of Customer’s non-acceptance thereof, whereupon the parties’ rights, remedies, and obligations will be
as set forth in Section 5.6 and Section 5.7; or ]

 

(ii)  provide Developer
with a written notice of its Acceptance of such Software Deliverable or Aggregate Software.

 

    

     

    

 

 

    5.6  Failure
of Acceptance Tests. If Acceptance Tests identify any Non-Conformities, Developer, at Developer’s sole cost and expense,
shall remedy all such Non-Conformities and re-deliver the Software Deliverable(s), in accordance with the applicable requirements
set forth in Exhibit D as promptly as commercially possible and, in any case, within two (2) days following, as applicable,
its:

 

(a)  completion of
such Acceptance Tests, in the case of Acceptance Tests conducted by Developer; or

 

(b)  receipt of Customer’s
notice pursuant to Section 5.5(a) identifying any Non-Conformities, in the case of Acceptance Tests conducted by Customer.

 

    5.7  Repeated
Failure of Acceptance Tests. If Acceptance Tests identify any Non-Conformity in any Software Deliverable after a second or
subsequent delivery thereof, or Developer fails to re-deliver the Software Deliverable on a timely basis, Customer may, in its
sole discretion, by written notice to Developer:

 

(a)  continue the process
set forth in this Section 5;

 

(b)  accept the Software
Deliverable as a nonconforming deliverable, in which case the Fees therefor shall be reduced equitably to reflect the value of
the Software Deliverable as received relative to the value of the Software Deliverable had it conformed; or

 

(c)  deem the failure
to be a non-curable material breach of this Agreement and the relevant Statement of Work, and terminate this Agreement and such
Statement of Work in accordance with Section 14.3(b).

 

    5.8  Acceptance.
Acceptance of each Software Deliverable (subject, where applicable, to Customer’s right to Integration Testing) and Aggregate
Software shall occur on the date that is the earliest of the following (each, an “Acceptance”):

 

(a)  Customer’s
delivery of a notice accepting such Software Deliverable pursuant to Section 5.5(b) or [Section 5.5(c)/Section 5.5(c)(ii)];

 

(b)  Solely if Customer
is responsible for performing such Acceptance Tests or Integration Testing in Section 5.4(c), upon the expiration of the Testing
Period therefor if Customer has not notified Developer of one or more Non-Conformities prior thereto; or

 

(c)  Solely if Developer
is responsible for performing such Acceptance Tests or Integration Tests, the number of days specified in Section 5.5(c) after
Customer receives Developer’s Notice of Completion, if Customer’s fails to respond to such Notice of Completion prior
to such date.

 

6.  Training, Maintenance,
and Support.

 

    6.1  Training.
With respect to all Software, Developer shall provide Customer with such training as is set forth in the applicable Statement of
Work in accordance with the training specifications, including times and locations, set forth in such Statement of Work. [Unless
expressly provided in any Statement of Work, all training set forth in such Statement of Work shall be provided at no additional
charge to Customer, it being acknowledged and agreed that the development and other Fees include full consideration therefor.]
Customer may request, and if so requested, Developer shall provide on a timely basis, [additional] training at the rates specified
in Exhibit B.]

 

    6.2  Maintenance
and Support. With respect to all Software, Developer shall provide Customer with the Support Services set forth on Exhibit
E. Such Support Services shall be provided:

 

(a)  free of charge,
during the Warranty Period, it being acknowledged and agreed by the parties that the development and other Fees include full consideration
for such Services during such period; and

 

    

     

    

 

(b)  thereafter, for
so long as the Customer elects to receive Support and Maintenance Service for such Software, in consideration of Customer’s
payment of the Support Fee therefor as determined in accordance with the rates set forth in [Exhibit B/Exhibit E].

 

7.  Fees and Payment.

 

    7.1  Fees.
Subject to all terms and conditions set forth herein, and Developer’s performance of Services to Customer’s [reasonable]
satisfaction and Customer’s Acceptance of the applicable Deliverables, Customer shall pay Developer the fees set forth in
the applicable Statement of Work (”Fees”). All such Fees shall be determined in accordance with the fees, billing
rates, and discounts set forth in Exhibit B.

 

    7.2  Reimbursable
Expenses. Customer shall reimburse Developer, in accordance with Customer’s standard expense reimbursement policy in
effect from time to time for direct, documented, out-of-pocket [travel and lodging] expenses (”Reimbursable Expenses”)
incurred by Developer in performing its obligations, subject to the following:

 

(a)  All travel arrangements
shall conform to Customer’s standard travel policy applicable to its employees in effect from time to time.

 

(b)  Customer shall
only be obligated to reimburse Developer for travel approved in advance by Customer.]

 

(c)  Customer shall
have the right to require that all travel arrangements be made through Customer’s in-house or contracted outside travel agent.]

 

(d)  Any individual
expense item in excess of $50 shall require Customer’s prior written approval.]

 

Notwithstanding the foregoing or anything else contained
in this Agreement, in no event shall license fees, royalties, or other amounts incurred by Developer to any Permitted Subcontractor
or for any Third-Party Materials be a Reimbursable Expense[, except to the extent expressly stated otherwise in any Statement of
Work for the Services or Work Product to be provided thereunder.]]

   

    7.3  Taxes.
All fees set forth herein are [exclusive/inclusive] of taxes. [Customer/Developer] shall be responsible for all sales, use, and
excise taxes, and any other similar taxes, duties, and charges of any kind imposed by any federal, state, or local governmental
entity on any amounts payable by Customer hereunder[, other than any taxes imposed on, or with respect to, Developer’s income,
revenues, gross receipts, personnel, real or personal property, or other assets].

 

    7.4  Invoices.
Developer shall invoice Customer for Fees and Reimbursable Expenses in accordance with the invoicing schedule and requirements
set forth in Exhibit B. Developer shall submit each invoice in [both hard copy and] electronic format, via such delivery
means and to such address as are specified by Customer in writing from time to time. If more than one Statement of Work is outstanding,
Developer shall provide an aggregate invoice for all Fees being invoiced, together with separate invoices for each Statement of
Work. Each separate invoice shall:

 

    

     

    

 

(a)  clearly identify
the Statement of Work to which it relates, in such manner as is required by Customer;

 

(b)  list each Fee
item and Reimbursable Expense separately;

 

(c)  include sufficient
detail for each line item to enable Customer to verify the calculation thereof;

 

(d)  [for Fees determined
on a time and materials basis, report details of time taken to perform Services, and such other information as Customer requires,
on a per-individual basis;]

 

(e)  be accompanied
by all [original] supporting documentation required hereunder for Reimbursable Expenses; and

 

(f)  include such other
information as may be required by Customer as set forth in Exhibit B or the applicable Statement of Work.

 

    7.5  Payment.

 

(a)  Subject to the
terms and conditions of this Section 7.5, Customer shall pay all properly invoiced Fees and Reimbursable Expenses within 10 days
after the later of:

 

(i)  Customer’s
receipt of the proper invoice therefor; or

 

(ii) the due date
for such amounts as set forth in the applicable Statement of Work[, which for Fees based on Developer’s provision of a specified
Deliverable shall not be earlier than Customer’s Acceptance of such Deliverable].

 

(b)  [Customer shall
be entitled to a discount of [two percent (2%)] of Fees (but not Reimbursable Expenses) paid within ten (10) days following the
due date determined pursuant to Section 7.5(a).]

 

(c)  Customer may withhold
from payment any amount disputed by Customer in good faith, pending resolution of the dispute[./, provided that Customer:

 

(i)   timely pays all
amounts not subject to dispute;

 

(ii)  notifies Developer
of the dispute prior to the due date, specifying in such notice (A) the amount in dispute, and (B) the reason for the dispute set
out in sufficient detail to facilitate investigation by Developer and resolution by the parties;

 

(iii) works with
Developer in good faith to resolve the dispute promptly; and

 

(iv) promptly pays
any amount determined to be due by resolution of the dispute.]

 

Developer shall continue performing
its obligations in accordance with this Agreement notwithstanding any such dispute or actual or alleged nonpayment that is the
subject of the dispute, pending its resolution.

 

(d)   All payments
hereunder shall be in digital currency FF or US dollars and made, at Customer’s option, by check or wire transfer or the
other ways agreed by both sides of developer and customer. Payments shall be made to the address or account specified in Exhibit
B or such other address or account as is specified by Developer in writing from time to time, provided that Developer shall
give Customer at least ten 10 days’ prior notice of any account, address or other change in payment instructions. Customer
will not be liable for any late or misdirected payment caused by Developer’s failure to provide timely notice of any such
change.

 

    

     

    

 

    7.6  Form
of Payment. All payments hereunder will be in FF or US dollars or made, at Customer’s option. Payments will be made to
the address or account specified by Developer in writing from time to time, provided that Developer shall give Customer at least
10 business days’ prior notice of any account, address, or other change in payment instructions. Customer will not be liable
for any late or misdirected payment caused by Developer’s failure to provide timely notice of any such change.

 

    7.7  Payment
Disputes. Customer may withhold from payment any and all payments and amounts Customer disputes in good faith, pending resolution
of such dispute, provided that Customer:

 

(a)  timely renders
all payments and amounts that are not in dispute;

 

(b)  notifies Developer
of the dispute prior to the due date for payment, specifying in such notice:

 

(i)   the amount in
dispute; and

 

(ii)  the reason for
the dispute set out in sufficient detail to facilitate investigation by Developer and resolution by the parties;

 

(c)  works with Developer
in good faith to resolve the dispute promptly; and

 

(d)  promptly pays
any amount determined to be payable by resolution of the dispute].

 

    Developer
shall not withhold any Services or fail to perform any obligation hereunder by reason of Customer’s good faith withholding
of any payment or amount in accordance with this Section 7.7 or any dispute arising therefrom.

 

    7.8  Firm
Pricing/Fee Changes.

 

(a)  [Except as provided
in this Section 7.2, t/T]he Fees set forth in Exhibit B are firm and shall not be modified during the Term.

 

(b)  [Subject to Section
7.8(c), Developer may increase the Fees, effective on any anniversary of the Effective Date, provided, however, that:

 

(i)   no increase in
Fees made prior to the first anniversary of the Support Commencement Date for any Software shall apply with respect to Support
Services for such Software; and

 

(ii)  no increase
in Fees shall apply with respect to any previously agreed Services or Work Product under any Statement of Work executed before
the effective date of such increase.

 

(c)  With respect to
any increase in Fees, Developer shall:

 

(i)   give Customer
at least 90 days’ prior written notice of any such change; and

 

(ii)  only increase
Fees to reflect its actual cost increases and, in any case, not increase Fees by a percentage that exceeds [80% of] the percentage
by which then most-recently published (”CPI”) exceeds the CPI as of the Effective Date or, if later,
the immediately preceding change in such billing rate, if any.

 

    

     

    

 

No increase in Fees shall be
effective unless made fully in compliance with the provisions of this Section 7.2.

 

    7.9  Most
Favored Pricing. At all times during the Term, the Fees and other charges hereunder shall be the lowest fees and rates contemporaneously
charged by Developer to any of its customers for similar volumes of goods and services of the same or comparable type and scope.
If at any time Developer charges any comparable customer a lower fee, rate, or price for similar volumes of such comparable goods
or services than the corresponding Fees charged hereunder, Developer shall immediately apply such lower rate or amount, as applicable,
for all comparable Deliverables, Services, and other Work Product provided to Customer. Such lower rates or amounts, as applicable,
shall apply retroactively to the date on which Developer began charging them to such comparable customer.]

 

    7.10  Right
of Set-off. Without prejudice to any other right or remedy it may have, Customer reserves the right to set-off at any time
any amount owing to it by Developer against any amount payable by Customer to Developer under this Agreement [or otherwise].]

 

    7.11  Auditing
Rights and Required Records. During the Term [and for [5] year[s] after expiration thereof], Developer shall maintain complete
and accurate books and records regarding its business operations relevant to the calculation of Fees, Reimbursable Expenses, and
any other information relevant to Developer’s representations, warranties, and covenants under this Agreement. During the
Term [and for [5] year[s] thereafter], upon Customer’s request, Developer shall make such books and records, and appropriate
personnel, available during normal business hours for inspection or audit by Customer or its authorized representative, provided
that Customer shall:

 

(a)  provide Developer
with [at least30 days] prior notice of any audit;

 

(b)  undertake an audit
no more than once per calendar year; and

 

(c)  conduct or cause
to be conducted such audit in a manner designed to minimize disruption of Developer’s normal business operations.

 

    Customer
will pay the cost of such audits unless an audit reveals an overbilling or over-reporting of [five] percent (5%) or more, in which
case Developer shall reimburse Customer for the [reasonable] cost of the audit. Developer shall immediately upon notice from Customer
pay Customer the amount of any overpayment revealed by the audit, together with any reimbursement pursuant to the preceding sentence.]

 

8.  Confidentiality.

 

    8.1  Confidential
Information. In connection with this Agreement, each party (the “Disclosing Party”) may disclose or make
available Confidential Information to the other party (the “Receiving Party”). Subject to Section 8.1, “Confidential
Information” means information in any form or medium (whether oral, written, electronic, or other) that the Disclosing
Party considers confidential or proprietary, including information consisting of or relating to the Disclosing Party’s technology,
trade secrets, know-how, business operations, plans, strategies, customers, and pricing, and information with respect to which
the Disclosing Party has contractual or other confidentiality obligations, in each case whether or not marked, designated or otherwise
identified as “confidential.” [Without limiting the foregoing, the financial terms and existence of this Agreement
are the Confidential Information of [Customer/ both Parties].]

 

    

     

    

 

    8.2  Exclusions.
Confidential Information does not include information that[ the Receiving Party can demonstrate by written or other documentary
records]: (a) was rightfully known to the Receiving Party without restriction on use or disclosure prior to such information’s
being disclosed or made available to the Receiving Party in connection with this Agreement; (b) was or becomes generally known
by the public other than by the Receiving Party’s or any of its Representatives’ non-compliance with this Agreement;
(c) was or is received by the Receiving Party on a non-confidential basis from a third party that[, to the Receiving Party’s
knowledge,] was not or is not, at the time of such receipt, under any obligation to maintain its confidentiality; or (d) [the Receiving
Party can demonstrate by written or other documentary records] was or is independently developed by the Receiving Party without
reference to or use of any Confidential Information.

 

    8.3  Protection
of Confidential Information. As a condition to being provided with any disclosure of or access to Confidential Information,
the Receiving Party shall for three years:

 

(a)  not access or
use Confidential Information other than as necessary to exercise its rights or perform its obligations under and in accordance
with this Agreement;

 

(b)  except as may
be permitted by and subject to its compliance with The Receiving Party shall be responsible for any breach of or non-compliance
with this Section 8 by any of its Representatives., not disclose or permit access to Confidential Information other than to its
Representatives who: (i) need to know such Confidential Information for purposes of the Receiving Party’s exercise of its
rights or performance of its obligations under and in accordance with this Agreement; (ii) have been informed of the confidential
nature of the Confidential Information and the Receiving Party’s obligations under this Section 8.3; and (iii) are bound
by [written] confidentiality and restricted use obligations at least as protective of the Confidential Information as the terms
set forth in this Section 8.3;

 

(c)  safeguard the
Confidential Information from unauthorized use, access or disclosure using at least the degree of care it uses to protect its [most/similarly]
sensitive information and in no event less than a reasonable degree of care; and

 

(d)  ensure its Representatives’
compliance with, and be responsible and liable for any of its Representatives’ noncompliance with, the terms of this Section
8.

 

The Receiving Party shall be responsible for any breach
of or non-compliance with this Section 8 by any of its Representatives.

 

    8.4  Compelled
Disclosures. If the Receiving Party or any of its Representatives is compelled by applicable Law to disclose any Confidential
Information then, to the extent permitted by applicable Law, the Receiving Party shall: (a) promptly, and prior to such disclosure,
notify the Disclosing Party in writing of such requirement so that the Disclosing Party can seek a protective order or other remedy,
or waive its rights under Section 8.2; and (b) provide reasonable assistance to the Disclosing Party[, at the Disclosing Party’s
sole cost and expense,] in opposing such disclosure or seeking a protective order or other limitations on disclosure. If the Disclosing
Party waives compliance or, after providing the notice and assistance required under this Section 8.4, the Receiving Party remains
required by Law to disclose any Confidential Information, the Receiving Party shall disclose only that portion of the Confidential
Information that[, on the advice of the Receiving Party’s [outside] legal counsel, ]the Receiving Party is legally required
to disclose [and, upon the Disclosing Party’s request, shall use commercially reasonable efforts to obtain assurances from
the applicable court or other presiding authority that such Confidential Information will be afforded confidential treatment].

 

    

     

    

 

9.  Intellectual Property
Rights.

 

    9.1  Customer
Ownership of Work Product.

 

    [Except
as set forth in Section 9.3,] Customer is and will be the sole and exclusive owner of all right, title, and interest in and to
all Work Product, including all Intellectual Property Rights therein. In furtherance of the foregoing[, subject to Section 9.3]:

 

(a)  Developer shall
create all Work Product as work made for hire as defined in Section 101 of the Copyright Act of 1976; and

 

(b)  To the extent
any Work Product or Intellectual Property Right therein does not qualify as, or otherwise fails to be, work made for hire, Developer
shall, and hereby does:

 

(i)  assign, transfer,
and otherwise convey to Customer, irrevocably and in perpetuity, throughout the universe, all right, title, and interest in and
to such Work Product, including all Intellectual Property Rights therein; and

 

(ii)  irrevocably
waive any and all claims Developer may now or hereafter have in any jurisdiction to so-called “moral rights” or rights
of droit moral with respect to the Work Product.

 

    9.2  Further
Actions. Developer shall, and shall cause the Developer Personnel to, take all appropriate action and execute and deliver all
documents necessary or reasonably requested by Customer to effectuate any of the provisions or purposes of Section 9.1 or otherwise,
as may be necessary or useful for Customer to prosecute, register, perfect, record, or enforce its rights in or to any [Customer-Owned]
Work Product or any Intellectual Property Right therein. Developer hereby appoints Customer as Developer’s attorney-in-fact
with full irrevocable power and authority to take any such actions and execute any such documents if Developer refuses, or within
a period deemed reasonable by Customer otherwise fails, to do so.

 

    9.3  [Background
Technology [and/,]]Approved Third-Party Materials[, and Approved Open Source Components].

 

(a)  [Developer is
and will remain the sole and exclusive owner of all right, title, and interest in and to the Background Technology, including all
Intellectual Property Rights therein, subject to the license granted in Section 10.1.]

 

(b)  Ownership of all
Approved Third-Party Materials, and all Intellectual Property Rights therein, is and will remain with the respective owners thereof,
subject to any express licenses or sublicenses granted to Customer pursuant to or in accordance with this Agreement.

 

(c)  [Ownership of
all Approved Open Source Components, and all Intellectual Property Rights therein, is and will remain with the respective owners
thereof, subject to Customer’s rights under the applicable Open Source Licenses.]

 

    9.4  Customer
Materials. Customer and its licensors are and will remain the sole and exclusive owners of all right, title, and interest in
and to the Customer Materials, including all Intellectual Property Rights therein. Developer shall have no right or license to,
and shall not, use any Customer Materials except solely during the Term of the Statement of Work(s) for which they are provided
to the extent necessary to perform the Services and provide the Work Product to Customer. All other rights in and to the Customer
Materials are expressly reserved by Customer.

 

    

     

    

 

10.  Licenses.

 

    10.1  [Background
Technology License. Developer hereby grants to Customer such rights and licenses with respect to the Background Technology
that will allow Customer to use and otherwise exploit perpetually throughout the universe for all or any purposes whatsoever [the
Work Product, to the same extent as if Customer owned] the Background Technology, without incurring any fees or costs to Developer
(other than the Fees and Reimbursable Expenses set forth herein) or any other Person in respect of the Background Technology. In
furtherance of the foregoing, such rights and licenses shall:

 

(a)  be irrevocable,
perpetual, fully paid-up, and royalty-free;

 

(b)  include the rights
to use, reproduce, perform (publicly or otherwise), display (publicly or otherwise), modify, improve, create derivative works of,
distribute, import, make, have made, sell, and offer to sell the Background Technology, including all such modifications, improvements,
and derivative works thereof[, solely as part of, or as necessary to use and exploit, the Work Product]; and

 

(c)  be freely assignable
and sublicensable[, in each case solely in connection with the assignment or licensing of the Work Product or any portion, modification,
or derivative work thereof, and only to the extent necessary to allow the assignee or sublicensee, as the case may be, to use and
exploit the Work Product or portion, modification, improvement, or derivative work thereof].

 

    Developer
reserves all rights in the Background Technology not expressly granted to Customer herein.]

 

    10.2  Customer
Materials. Customer hereby grants to Developer the limited, royalty-free, non-exclusive right and license to Customer Materials
solely as necessary to incorporate such Customer Materials into, or otherwise use such Customer Materials in connection with creating,
the Work Product. The term of such license shall commence upon Customer’s delivery of the Customer Materials to Developer,
and shall terminate upon Customer’s acceptance or rejection of the Work Product to which the Customer Materials relate. Subject
to the foregoing license, Customer reserves all rights in the Customer Materials. Customer Materials shall be deemed Customer’s
Confidential Information.

 

    10.3  Approved
Third-Party Materials.

 

(a)  Developer hereby
grants, or prior to the delivery date for any Deliverables under the Initial Statement of Work shall procure for Customer the grant
of, such licensed rights in the Approved Third-Party Materials set forth in Exhibit C.

 

(b)  [On or prior to
the execution of each Statement of Work/Not later than the date specified in any Statement of Work, ]Developer shall secure for
Customer, at Developer’s sole cost and expense, such rights, licenses, consents, and approvals as are specified in Exhibit
C or such Statement of Work.

 

(c)  All royalties,
license fees, or other consideration payable in respect of such licenses are included in the Fees specified in each Statement of
Work unless such Statement of Work expressly states otherwise. Any additional amounts shall be the sole responsibility of Developer.

 

    

     

    

 

    10.4  Approved
Open Source Components. Any use of the Approved Open Source Components by the Customer will be governed by, and subject to,
the terms and conditions of the applicable Open Source Licenses.]

 

11.  Representations and Warranties.

 

    11.1  Mutual
Representations and Warranties.

 

    Each
party represents and warrants to the other party that:

 

(a)  it is duly organized,
validly existing, and in good standing as a corporation or other entity as represented herein under the Laws of its jurisdiction
of incorporation or organization;

 

(b)  it has the full
right, power, and authority to enter into this Agreement, to grant the rights and licenses granted hereunder, and to perform its
obligations hereunder;

 

(c)  the execution
of this Agreement by its representative whose signature is set forth at the end hereof has been duly authorized by all necessary
[corporate/organizational] action of the party; and

 

(d)  when executed
and delivered by both parties, this Agreement will constitute the legal, valid, and binding obligation of such party, enforceable
against such party in accordance with its terms.

 

    11.2  Additional
Representations and Warranties. Developer represents and warrants to Customer that:

 

(a)  it will perform
all Services in a professional and workmanlike manner in accordance with [best/generally recognized/commercially reasonable] industry
standards and practices for similar services, using personnel with the requisite skill, experience, and qualifications, and shall
devote adequate resources to meet its obligations under this Agreement;

 

(b)  It is in compliance
with, and will perform all Services in compliance with, all applicable Law;

 

(c)  Customer will
receive good and valid title to all Work Product, free and clear of all encumbrances and liens of any kind;

 

(d)  When delivered
[and installed by Developer], no Software Deliverable will contain any Harmful Code;

 

(e)  All Work Product,
including all updates, upgrades, new versions, new releases, enhancements, improvements, and other modifications thereof, but excluding
Customer Materials, [and] Approved Third-Party Materials[, and Approved Open Source Components], is or will be the original creation
of Developer;

 

(f)  As delivered,
installed, specified, or approved by Developer and used by Customer or any Third Party authorized by Customer[, in accordance with
this Agreement and the Documentation], the Work Product (excluding Customer Materials): (i) will not infringe, misappropriate,
or otherwise violate any Intellectual Property Right or other right of any third party; and (ii) will comply with all applicable
Laws.

 

    11.3  Performance
Warranty and Limited Remedy.

 

(a)  Developer warrants
that during the Warranty Period therefor:

 

    

     

    

 

(i)  all Software
will be, and as installed in the Operating Environment (or any successor thereto) and used in accordance with the Documentation
will function in all respects, in conformity with this Agreement and the Specifications and Documentation therefor; and

 

(ii)  any media on
which any Software Deliverable is delivered will be free of damage or defect in design, material, and workmanship, and will remain
so under ordinary use as contemplated by this Agreement and the Specifications and, with respect to the Software component thereof,
the Documentation therefor.

 

(b)  If the Developer
breaches any of the warranties set forth in Section 11.3(a), Developer shall, upon written notice from Customer and at Developer’s
sole cost and expense, remedy such breach in accordance with Exhibit E, including the time periods set forth therein. In
the event Developer fails to remedy such breach on a timely basis, Customer shall be entitled to such remedies as are specified
in Exhibit E or as may otherwise be available under this Agreement, at law, or in equity for Developer’s breach of
its Support Services obligations. Nothing in this Section 11.3(b) shall limit Customer’s right to indemnification pursuant
to Section 12.1.

 

    11.4  DISCLAIMER.
EXCEPT FOR THE EXPRESS WARRANTIES SET FORTH IN THIS AGREEMENT, EACH PARTY HEREBY DISCLAIMS ALL WARRANTIES, WHETHER EXPRESS, IMPLIED,
STATUTORY, OR OTHERWISE, WITH RESPECT TO THIS AGREEMENT.

 

12.  Indemnification.

 

    12.1  General
Indemnification. Developer shall defend, indemnify, and hold harmless Customer and each of Customer’s Affiliates and
its and their respective officers, directors, employees, agents, contractors, successors, and assigns (each, a “Customer
Indemnitee”) from and against any and all Losses incurred by the Customer Indemnitee resulting from any Action by a third
party (other than an Affiliate of the Customer Indemnitee) [to the extent that such Losses/that] arise out of or result from, or
are alleged to arise out of or result from:

 

(a)  Developer’s
breach of any representation, warranty, covenant, or obligation of Developer (including any action or failure to act by any Permitted
Subcontractor that, if taken or not taken by Developer, would constitute such a breach by Developer) under this Agreement; or

 

(b)  any [action or
failure to take a required action/negligence/gross negligence] or more culpable act or omission (including recklessness or willful
misconduct) in connection with the performance or activity required by or conducted in connection with this Agreement by Developer
or any Permitted Subcontractor in connection with performing Services under this Agreement.

 

    12.2  Indemnification
Procedure. Customer will promptly notify Developer in writing of any Action for which it seeks to be indemnified pursuant to
Section 12.1 and cooperate with Developer at Developer’s sole cost and expense. Developer shall immediately take control
of the defense and investigation of such Action and shall employ counsel [of its choice/reasonably acceptable to Customer] to handle
and defend the same, at Developer’s sole cost and expense. Developer shall not settle any Action in a manner that adversely
affects the rights of Customer or any Customer Indemnitee without Customer’s prior written consent[, which shall not be unreasonably
withheld or delayed]. Customer’s failure to perform any obligations under this Section 12.2 will not relieve Developer of
its obligations under Section 12.1 except to the extent that Developer can demonstrate that it has been [materially] prejudiced
as a result of such failure. Customer may participate in and observe the proceedings at its own cost and expense with counsel of
its own choosing.

 

    

     

    

 

    12.3  Infringement
Remedy.

 

(a)  If any Software
or any component thereof, other than Customer Materials, is found to be infringing or if any use of any Software or any component
thereof is enjoined, threatened to be enjoined, or otherwise the subject of an infringement claim, Developer shall, at Developer’s
sole cost and expense:

 

(i)  procure for Customer
the right to continue to use such Software or component thereof to the full extent contemplated by this Agreement; or

 

(ii)  modify or replace
the materials that infringe or are alleged to infringe (”Allegedly Infringing Materials”) to make the Software
and all of its components non-infringing while providing fully equivalent features and functionality.

 

(b)  If neither of
the foregoing is possible notwithstanding Developer’s [best/commercially reasonable] efforts then Developer may direct Customer
to cease any use of any materials that have been enjoined or finally adjudicated as infringing, provided that Developer shall:

 

(i)  refund to Customer
all amounts paid by Customer in respect of such Allegedly Infringing Materials [and any other aspects of the Aggregate Software
provided under the Statement of Work for the Allegedly Infringing Materials that Customer cannot reasonably use as intended under
this Agreement]; and

 

(ii)  in any case,
at its sole cost and expense, secure the right for Customer to continue using the Allegedly Infringing Materials for a transition
period of up to [NUMBER IN WORDS] ([NUMBER]) month[s] to allow Customer to replace the affected features of the Software without
disruption.

 

(c)  If developer directs
Customer to cease using any Software pursuant to Section 12.3(b), Customer shall have the right to terminate any or all then-outstanding
Statements of Work [and this Agreement] for cause pursuant to Section 14.3(b)(i).

 

(d)  The remedies set
forth in this Section 12.3 are in addition to, and not in lieu of[, all other remedies that may be available to Customer under
this Agreement or otherwise, including] Customer’s right to be indemnified for such Actions.

 

13.  Limitations of Liability.

 

    13.1  EXCLUSION
OF INDIRECT DAMAGES. EXCEPT AS OTHERWISE PROVIDED IN SECTION 13.3, IN NO EVENT WILL EITHER PARTY BE LIABLE UNDER THIS AGREEMENT,
INCLUDING ANY STATEMENT OF WORK, FOR ANY CONSEQUENTIAL, INCIDENTAL, INDIRECT, EXEMPLARY, SPECIAL, OR PUNITIVE DAMAGES WHETHER ARISING
OUT OF BREACH OF CONTRACT, TORT (INCLUDING NEGLIGENCE), OR OTHERWISE, REGARDLESS OF WHETHER SUCH DAMAGE WAS FORESEEABLE AND WHETHER
EITHER PARTY HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES.

 

    13.2  [CAP
ON MONETARY LIABILITY. EXCEPT AS OTHERWISE PROVIDED IN SECTION 13.3, IN NO EVENT WILL EITHER PARTY’S LIABILITY UNDER
[THIS AGREEMENT/ANY STATEMENT OF WORK], EXCEED [[NUMBER IN WORDS] ([NUMBER]) TIMES] THE AGGREGATE FEES AND REIMBURSABLE EXPENSES
UNDER [THIS AGREEMENT/SUCH STATEMENT OF WORK] (INCLUDING AMOUNTS ALREADY PAID AND AMOUNTS THAT HAVE ACCRUED BUT NOT YET BEEN PAID)
[IN THE [NUMBER] [YEARS/MONTHS] PRECEDING THE EVENT GIVING RISE TO THE CLAIM].]

 

    

     

    

 

    13.3  [Exceptions.
The exclusions and limitations in Section 13.1 and Section 13.2 shall not apply to:

 

(a)  Losses arising
out of or relating to a party’s failure to comply with its obligations under Section 8 (Confidentiality) or Section 8 (Intellectual
Property Rights);

 

(b)  a party’s
indemnification obligations under Section 12 (Indemnification);

 

(c)  Losses arising
out of or relating to a party’s gross negligence, willful misconduct, or intentional acts;

 

(d)  Losses for death,
bodily injury, or damage to real or tangible personal property arising out of or relating to a party’s negligent or more
culpable acts or omissions; [or]

 

(e)  Losses to the
extent covered by a party’s insurance[; or

 

(f)  a party’s
obligation to pay attorneys’ fees and court costs in accordance with Section 15.18].]

 

14.  Term and Termination.

 

    14.1 Term.
The [initial] term of this Agreement commences as of the Effective Date and continues in effect until five (5) year[s] from such
date unless terminated earlier pursuant to any of its express provisions (the “[Initial] Term”).

 

    14.2 Renewal.
Unless this Agreement is terminated earlier pursuant to any of its express provisions, Customer may renew this Agreement for additional
successive 5 year terms by providing Developer with written notice/this Agreement automatically renews for additional successive
5 year terms unless and until [either Party/Customer] provide[s] written notice of non-renewal] at least 30 days prior to the end
of the then-current term (each a “Renewal Term” and, collectively, together with the Initial Term, the “Term”).]

 

    14.3  Termination.

 

(a)  Customer may terminate,
at any time without cause, and without incurring any additional obligation, liability or penalty:

 

(i)  this Agreement,
by written notice to Developer;

 

(ii)  Support Services
for all or any Software, by providing at least five (5) days’ prior written notice to Developer; or

 

(iii)  except as may
be set forth in therein, any Statement of Work, by providing at least five (5) days’ prior written notice to Developer.

 

(b)  Either party may
terminate this Agreement, the Support Services, and any outstanding Statement[s] of Work, effective upon written notice to the
other party, if the other party [materially] breaches this Agreement, Support Services, or such Statement[s] of Work, and such
breach:

 

    

     

    

 

(i)  is incapable
of cure; or

 

(ii)  being capable
of cure, remains uncured five (5) days after the breaching party receives written notice thereof.

 

(c)  Either party may
terminate this Agreement, the Support Services, and all Statements of Work by written notice to the other party if the other party:

 

(i)  becomes insolvent
or admits inability to pay its debts generally as they become due;

 

(ii)  becomes subject,
voluntarily or involuntarily, to any proceeding under any domestic or foreign bankruptcy or insolvency law which is not fully stayed
within [seven] (7) business days or is not dismissed or vacated within [forty-five] (45) days after filing;

 

(iii)  is dissolved
or liquidated or takes any corporate action for such purpose;

 

(iv)  makes a general
assignment for the benefit of creditors; or

 

(v)  has a receiver,
trustee, custodian, or similar agent appointed by order of any court of competent jurisdiction to take charge of or sell any material
portion of its property or business.

 

    14.4  Effect
of Expiration or Termination.

 

(a)  Termination of
this Agreement shall not effectuate a termination of Support Services or any Statement of Work then in effect and not otherwise
expressly terminated, and the terms and conditions set forth herein shall continue in effect with respect to any such Support Services
and Statements of Work until their expiration or termination as set forth herein.

 

(b)  Upon any expiration
or termination of any Support Services or Statement of Work:

 

(i)  Developer shall
(A) with respect to termination of a Statement of Work, promptly deliver to Customer all Work Product generated by Developer under
such Statement of Work (whether complete or incomplete); (B) provide reasonable cooperation and assistance to Customer [upon Customer’s
written request and at Customer’s expense ] in transitioning the Services to an alternate service provider; and (C) on a
pro rata basis, repay all amounts, if any, paid in advance for any Services or Work Product that have not been provided.

 

(ii)  All licenses
granted to Developer in the Customer Materials with respect to such Services or Statement of Work shall immediately and automatically
also terminate, and Developer shall promptly return to Customer all Customer Materials not required by Developer for continuing
Support Services or Statements of Work hereunder, if any.

 

(iii)  Developer shall
(A) return to Customer all documents and tangible materials (and any copies) containing, reflecting, incorporating, or based on
Customer’s Confidential Information; (B) permanently erase Customer’s Confidential Information from its computer systems;
and (C) certify in writing to Customer that it has complied with the requirements of this Section 14.4(b)(iii), in each case to
the extent such materials are not required by Developer for continuing Support Services or Statements of Work hereunder, if any.

 

    

     

    

 

(c)  If Customer terminates
any Support Services or Statement of Work pursuant to Section 14.3(b), Customer shall be relieved of any obligation to pay any
Fees thereunder[, and Developer shall promptly refund to Customer all Fees previously paid in respect thereof. In such event, Customer
shall not retain any rights in or to the Deliverables thereunder (other than Customer Materials)].

 

(d)  Except as set
forth in Section 14.4(c), if this Agreement terminates early Customer will remain obligated to pay Fees for all Services and Work
Product received before the effective date of such termination.

 

(e)  [Except as set
forth in Section 14.4(c)[, no/No]] expiration or termination of this Agreement will affect Customer’s rights in any of the
Deliverables.

 

    14.5  Survival.
The rights and obligations of the parties set forth in this Section 14.5 and Section 1, Section 8.1, Section 8, Section 10.1, Section
10.3[, Section 10.4], Section 12, Section 13, and Section 14, and any right or obligation of the parties in this Agreement which,
by its express terms or nature and context is intended to survive termination or expiration of this Agreement, will survive any
such termination or expiration.

 

15.  Miscellaneous.

 

    15.1  Effect
of Developer Bankruptcy. All rights and licenses granted by Developer under this Agreement are and will be deemed to be rights
and licenses to “intellectual property,” and all Work Product is and will be deemed to be “embodiment[s]”
of “intellectual property,” for purposes of, and as such terms are used in and interpreted under, Section 365(n) of
the United States Bankruptcy Code (the “Code”) (11 U.S.C. § 365(n)). Customer shall have the right to exercise
all rights and elections under the Code and all other applicable bankruptcy, insolvency and similar laws with respect to this Agreement
and the subject matter hereof. [Without limiting the generality of the foregoing, Developer acknowledges and agrees that, if Developer
or its estate shall become subject to any bankruptcy or similar proceeding:

 

(a)  subject to Customer’s
rights of election, all rights and licenses granted to Customer under this Agreement will continue subject to the terms and conditions
of this Agreement, and will not be affected, even by Developer’s rejection of this Agreement; and

 

(b)  Customer shall
be entitled to a complete duplicate of (or complete access to, as appropriate) all such intellectual property and embodiments of
intellectual property, and the same, if not already in Customer’s possession, shall be promptly delivered to Customer, unless
Developer elects to and does in fact continue to perform all of its obligations under this Agreement.]

 

    15.2  Further
Assurances. On a party’s reasonable request, the other party shall, at such other party’s sole cost and expense,
execute and deliver all such documents and instruments, and take all such further actions, necessary to give full effect to this
Agreement.

 

    15.3  Relationship
of the Parties. The relationship between the parties is that of independent contractors. Nothing contained in this Agreement
shall be construed as creating any agency, partnership, joint venture, or other form of joint enterprise, employment, or fiduciary
relationship between the parties, and neither party shall have authority to contract for or bind the other party in any manner
whatsoever.

 

    

     

    

 

    15.4  Public
Announcements. Neither party shall issue or release any announcement, statement, press release, or other publicity or marketing
materials relating to this Agreement or, unless expressly permitted under this Agreement, otherwise use the other party’s
trademarks, services marks, trade names, logos, domain names, or other indicia of source, association, or sponsorship, in each
case, without the prior written consent of the other party.

 

    15.5  Notices.
[Except as otherwise expressly set forth in this Agreement, a/A]ll notices, requests, consents, claims, demands, waivers, and
other communications under this Agreement have binding legal effect only if in writing and addressed to a party as follows (or
to such other address or such other person that such party may designate from time to time in accordance with this Section 15.5).

 

	If to Developer:	 	 
	 	Email: tuozhang@xinyuan.cn	 
	 	Attention: LEO ZHANG	 
	 	 	 
	If to Customer:  	 	 
	 	Email: kentc@55.com  	 
	 	Attention: Kent Cai  	 

 

    Notices
sent in accordance with this Section shall be deemed effectively given: (a) when received, if delivered by hand, with signed confirmation
of receipt; (b) when received, if sent by a nationally recognized overnight courier, signature required; (c) when sent, if by facsimile
[or email], ([in each case,] with confirmation of transmission), if sent during the addressee’s normal business hours, and
on the next business day, if sent after the addressee’s normal business hours; and (d) on the [ORDINAL NUMBER] day after
the date mailed by certified or registered mail, return receipt requested, postage prepaid.

 

    15.6  Interpretation.
For purposes of this Agreement, (a) the words “include,” “includes” and “including” are deemed
to be followed by the words “without limitation”; (b) the word “or” is not exclusive; (c) the words “herein,”
 “hereof,” “hereby,” “hereto” and “hereunder” refer to this Agreement as a whole;
(d) words denoting the singular have a comparable meaning when used in the plural, and vice-versa; and (e) words denoting any gender
include all genders. Unless the context otherwise requires, references in this Agreement: (x) to sections, exhibits, attachments
and appendices mean the sections of, and exhibits, attachments and appendices attached to, this Agreement; (y) to an agreement,
instrument or other document means such agreement, instrument or other document as amended, supplemented and modified from time
to time to the extent permitted by the provisions thereof; and (z) to a statute means such statute as amended from time to time
and includes any successor legislation thereto and any regulations promulgated thereunder. The parties intend this Agreement to
be construed without regard to any presumption or rule requiring construction or interpretation against the party drafting an instrument
or causing any instrument to be drafted. The exhibits, attachments, and appendices referred to herein are an integral part of this
Agreement to the same extent as if they were set forth verbatim herein.

 

    

     

    

 

 

15.7  Headings.
The headings in this Agreement are for reference only and shall not affect the interpretation of this Agreement.

 

15.8  Entire
Agreement. This Agreement[, together with [the [OTHER DOCUMENTS]/any other documents incorporated herein by reference]], constitutes
the sole and entire agreement of the Parties with respect to the subject matter of this Agreement and supersedes all prior and
contemporaneous understandings, agreements, representations and warranties, both written and oral, with respect to such subject
matter. [In the event of any inconsistency between the statements made in the body of this Agreement, the related exhibits, schedules,
attachments and appendices [(other than an exception expressly set forth as such therein)] and [[OTHER DOCUMENTS]/any other documents
incorporated herein by reference], the following order of precedence governs: (a) first, this Agreement, excluding its exhibits,
schedules, attachments and appendices; (b) second, the exhibits, schedules, attachments and appendices to this Agreement as of
the Effective Date; and (c) third, any other documents incorporated herein by reference/[OTHER PRECEDENCE].]

 

15.9  Assignment.
Developer shall not assign or otherwise transfer any of its rights, or delegate or otherwise transfer any of its obligations or
performance, under this Agreement, in each case whether voluntarily, involuntarily, by operation of law, or otherwise, without
Customer’s prior written consent[, which consent Customer [shall not unreasonably withhold or delay/may give or withhold
in its sole discretion]]. [For purposes of the preceding sentence, and without limiting its generality, any merger, consolidation,
or reorganization involving Developer (regardless of whether Developer is a surviving or disappearing entity) will be deemed to
be a transfer of rights, obligations, or performance under this Agreement for which Customer’s prior written consent is required.]
No delegation or other transfer will relieve Developer of any of its obligations or performance under this Agreement. Any purported
assignment, delegation, or transfer in violation of this Section 15.9 is void. Customer may freely assign or otherwise transfer
all or any of its rights, or delegate or otherwise transfer all or any of its obligations or performance, under this Agreement
without Developer’s consent. This Agreement is binding upon and inures to the benefit of the parties hereto and their respective
permitted successors and assigns.

 

15.10  Export
Regulation. Customer shall not itself, or permit any third parties to, export, re-export, or release, directly or indirectly,
any Software to any country or jurisdiction to which the export, re-export or release of any Software (a) is prohibited by applicable
Law or (b) without first completing all required undertakings (including obtaining any necessary export license or other governmental
approval).

 

15.11  Force
Majeure.

 

(a)  Force Majeure
Events. In no event shall either party be liable or responsible to the other party, or be deemed to have defaulted under or
breached this Agreement, for any failure or delay in fulfilling or performing any term of this Agreement when and to the extent
such failure or delay is caused by any [of the following] circumstances beyond such party’s reasonable control ([each] a
 “Force Majeure Event”) [including/:] acts of God, flood, fire, earthquake or explosion, war, terrorism, invasion,
riot or other civil unrest, embargoes, or blockades in effect on or after the date of this Agreement, national or regional emergency,
strikes, labor stoppages, or slowdowns or other industrial disturbances, passage of Law or any action taken by a governmental or
public authority, including imposing an embargo, export or import restriction, quota, or other restriction or prohibition or any
complete or partial government shutdown, or national or regional shortage of adequate power or telecommunications or transportation.
Customer may terminate this Agreement if a Force Majeure Event affecting Developer continues substantially uninterrupted for a
period of [30/[NUMBER]] days or more.

 

    

    

    

 

(b)  Affected Party
Obligations. In the event of any failure or delay caused by a Force Majeure Event, the affected party shall give prompt notice
to the other party, stating the period of time the occurrence is expected to continue and use diligent efforts to end the failure
or delay and minimize the effects of such Force Majeure Event.]

 

15.12  No
Third-Party Beneficiaries. This Agreement is for the sole benefit of the parties hereto and their respective successors and
permitted assigns, and nothing herein, express or implied, is intended to or shall confer on any other person or entity any legal
or equitable right, benefit, or remedy of any nature whatsoever under or by reason of this Agreement.

 

15.13  Amendment
and Modification; Waiver. No amendment to or modification of [or rescission, termination or discharge of] this Agreement is
effective unless it is in writing [, identified as an amendment to [or rescission, termination or discharge of] this Agreement]
and signed by [an authorized representative of] each party. No waiver by any party of any of the provisions hereof is effective
unless explicitly set forth in writing and signed by the party so waiving. Except as otherwise set forth in this Agreement, no
failure to exercise, or delay in exercising, any rights, remedy, power, or privilege arising from this Agreement will operate or
be construed as a waiver thereof; nor will any single or partial exercise of any right, remedy, power or privilege hereunder preclude
any other or further exercise thereof or the exercise of any other right, remedy, power or privilege.

 

15.14  Severability.
If any provision of this Agreement is invalid, illegal, or unenforceable in any jurisdiction, such invalidity, illegality, or unenforceability
will not affect any other term or provision of this Agreement or invalidate or render unenforceable such term or provision in any
other jurisdiction. Upon such determination that any term or other provision is invalid, illegal, or unenforceable, the parties
hereto shall negotiate in good faith to modify this Agreement so as to effect the original intent of the parties as closely as
possible in a mutually acceptable manner in order that the transactions contemplated hereby be consummated as originally contemplated
to the greatest extent possible.

 

15.15  Governing
Law; Submission to Jurisdiction. This Agreement is governed by and construed in accordance with the internal laws of the State
of [STATE] without giving effect to any choice or conflict of law provision or rule that would require or permit the application
of the laws of any jurisdiction other than those of the State of [STATE]. Any legal suit, action, or proceeding arising out of
[or related to] this Agreement or the licenses granted hereunder [will/may] be instituted [exclusively] in the federal courts
of the United States or the courts of the State of [STATE] in each case located in the city of [CITY] and County of [COUNTY],
and each party irrevocably submits to the [exclusive] jurisdiction of such courts in any such suit, action, or proceeding. Service
of process, summons, notice, or other document by mail to such party’s address set forth herein will be effective service
of process for any suit, action, or other proceeding brought in any such court.

 

15.16  Waiver
of Jury Trial. Each party irrevocably and unconditionally waives any right it may have to a trial by jury in respect of any
legal action arising out of or relating to this Agreement or the transactions contemplated hereby.]

 

15.17  Equitable
Relief. Each party acknowledges that a breach or threatened breach by a party of Section 8 or Section 8 would cause the other
party irreparable harm for which monetary damages would not be an adequate remedy and agrees that, in the event of such breach
or threatened breach, the other party will be entitled to equitable relief, including a restraining order, an injunction, specific
performance and any other relief that may be available from any court, without any requirement to post a bond or other security,
or to prove actual damages or that monetary damages are not an adequate remedy. Such remedies are not exclusive and are in addition
to all other remedies that may be available at law, in equity, or otherwise.

 

    

    

    

 

15.18  Attorneys’
Fees. In the event that any action, suit, or other legal or administrative proceeding is instituted or commenced by either
party hereto against the other party arising out of [or related to] this Agreement, the prevailing party is entitled to recover
its [reasonable/actual] attorneys’ fees and court costs from the non-prevailing party.]

 

15.19  Counterparts.
This Agreement may be executed in counterparts, each of which is deemed an original, but all of which together are deemed to be
one and the same agreement. [A signed copy of this Agreement delivered by facsimile, email, or other means of electronic transmission
is deemed to have the same legal effect as delivery of an original signed copy of this Agreement.]

 

    

    

    

 

IN WITNESS WHEREOF, the Parties hereto
have executed this Agreement as of the Effective Date.

 

	BGA FOUNDATION LTD	 	Unicorn Investment Limited
	 	 	 
	By:	/s/ Li Kefeng (with seal of BGA 	 	By:	/s/ Wu Longming (with seal of
	FOUNDATION LTD)	 	Unicorn Investment Limited)
	Name:	Li Kefeng	 	Name:	Wu Longming
	Title:	 	 	Title:	 

 

EXHIBIT A

STATEMENTS OF WORK, BUSINESS REQUIREMENTS
SPECIFICATION, AND RFP

EXHIBIT B

FEES

EXHIBIT C

APPROVED THIRD-PARTY MATERIALS AND APPROVED
OPEN SOURCE COMPONENTS

EXHIBIT D

DELIVERY, TESTING, AND ACCEPTANCE CRITERIA

EXHIBIT E

SUPPORT SERVICES

 

    

     

    

 

EXHIBIT A

STATEMENTS OF WORK, BUSINESS REQUIREMENTS
SPECIFICATION, AND RFP

 

Initial Statement of Work

 

This Initial Statement of Work is entered
into by and between BGA Foundation LTD (“BGA”) and Unicorn Investment Limited (“Unicorn”)
and is hereby incorporated into and made a part of Master Services Agreement (the “Agreement”), effective as
of May 28, 2018 by and between BGA and Unicorn Unless otherwise defined herein, all capitalized terms that are used in this Initial
Statement of Work will have the meanings given to such terms in the Agreement. The effective date of this Initial Statement of
Work is May 28, 2018.

 

		1.	GENERAL INFORMATION

 

	Name of Software:	Digital Currency Exchange Platform
	Object of Software Development Service:	
        (1) Provide a complete and
        effective set of configuration management for institutes, end users and other rollers; authority control function available on
        platform.

         

        (2) Platform maintainers can
        observe and inspect operation status through monitoring module.

         

        (3) B/S structure, benefit
        for fault tolerance and easier system upgrade

         

        (4) The deployment on platform
        is subject to principle of easy-to-use.

         

        (5) Provide stable & reliable
        operation; support high concurrency.

         

        (6) High extensions and good
        standardization, to meet the technical requirements of trade matching.

         

        (7) Provide complete
        know-how files: demand features analysis, system design, platform operation, use training

         

        (8) Good Second
        development; support tailored development need.

         

	Project start date:

                                                                                 
	2018-06-01
	Completion date:

                                                                                 
	2018-09-25
	
        Unicorn 

         

        Project Manager

         
	
        Name: Leo Zhang

         

        Email: tuozhang@xinyuan.cn

         

	
        BGA 

         

        Project Manager

         
	
        Name: Kent Cai

         

        Email: kentc@55.com

         

 

    

    

    

 

		2.	FUNCTIONAL SPECIFICATION

 

	System / Product	Function	Description
	Core Trading Module 	Trade Matching	Full-memory, distributed, micro service architecture, extensible trade matching
	Multiple API supporting	 
	Multiple Language	 
	Token Management Module	Token Wallet	Token: BTC、ETH、USDT、EOS
	Deposit/Withdrawal	2-D code, Transaction record
	Enquiry	Account balance, Transaction record
	Hot wallet management	Enquiry, deposit, withdrawal
	Cold wallet management	Enquiry, deposit, withdrawal
	Private key	Generate address, private key deriving
	Procedure management	Work flows setup
	Customer Counter Module	Home page	Eye-catching banners, announcement, pairs recommendation, APP download
	Login/registration	Log in, Email registration, Mobile phone registration, retrieve password
	Trading Center	Type selection, Plate selection, trading pairs selection, pricing/trend, K line
	Asset	Total Assets, classified assets, deposit, withdrawal, address management, transaction history
	My order	Current commission, history commission, transaction details
	Security	Security grade, login password, trading password, phone number verification, E-mail verification, google Authentication, ID verification
	others	About us, multiple languages
	Operation Management Module	Invitation	Poster sharing, link sharing, invitation records
	On listing	On-listing application, listing audit 
	Activities	Ad management
	Reporting/statistics accounting	Operation, accounting,
    statistic, finance report, tailored items
	Voting system	Listing vote, vote audit
	Airdrop 	Address fillin, batch airdrop,support  ETH,EOS
	Mining system	Trading mining, activities statistics
	Work flow engine	Self-defined procedures
	Mobility management	API, service provider management
	Customer service	Online service; service management backstage

 

    

    

    

 

	
        APP

         

        APP/H5

         
	IOS	Iphone6 and higher version
	Android	
        10+ types of phone and screen

         

         

         

	H5	
        5 types of browsers

         

         

         

	
        OTC Trading System

         

        OTC Module

         
	Ad posting	
        Ad listing, ad content, ad posting, ad editing

         

	IM 	Online communication, data memory
	Order and trading	
        users’ online status, order, matching orders

         

	Asset management	
        Overview, asset transfer, deposit, asset recording

         

	Appeal	Appeal, Processing, account frozen
	Credit 	
        Comments by users, blacklist, user reputation, user grade

         

 

    

    

    

 

		3.	TECHICAL SPECIFICATION

 

	
        General requirements

         

         

         
	
        (1) Meet forecasting concurrency
        need in different sections/plates on trading peak time after official launch of the platform.

         

        (2) Support multiple integration:
        Socket, HTTP, SDK and Webservice

         

        (3) Brief and wieldy interface;
        tailored function available

         

        (4) Modularized design, parameterized
        management, automatic processing, facilitate tech staff in development and maintaining

         

	Capacity 	
        (1) Installation on PC Server
        group; stable and reliable operation under VMware

         

        (2) Consecutive, stable and
        efficient operation 7*24

         

        (3) Perfect system service
        start-stop mechanism

         

        (4) Effective and stable batched
        data processing

         

        (5) stable online service
        during batched data processing

         

	language
tools,

                                                                                                                                       operation system for development 
	
        (1) Frontend development: IOS/Android、Html、JS

         

        (2) Backend development: Java+MySQL

         

        (3) Testing environment:
        AliCloud/AWS

         

        (4) Producing environment:
        AliCloud/AWS

         

	Data security	
        (1) Ensure the correctness,
        integrity, consistency and safety of data in the processing and transmission.

         

        (2) Encrypted storage plan
        for key info and data

         

        (3) The platform ensures the
        data integrity through the intactness of the whole transaction. The security of data is ensured by fault tolerance of hardware
        malfunction as well as recovery and maintaining of logs and data.

         

        (4) Software fault tolerance: validate
        verification; the protection pattern from database; protecting current status automatically and conduct quick recovery.

         

	Internet security	
        (1) Complete data encryption
        and transmission encryption, no plain text in key information in transmission process.

         

        (2) Software and hardware
        encryption in transmission process.

         

        (3) Resume breakpoint, retransmission,
        track whole transmission. No FTP and other unsafe transmission ways allowed.

         

 

This Initial Statement of Work will become
effective upon execution by both Parties below and Unicorn will thereafter develop the Software in accordance with the terms set
forth herein. Any change to this Initial Statement of Work after it is approved must be agreed by the Parties in a written amendment.

 

	BGA Foundation LTD	 	Unicorn Investment Limited.
	 	 	 
	/s/ Li Kefeng (with seal of BGA Foundation LTD)	 	/s/ Wu Longming (with seal of Unicorn Investment Limited)
	Signature	 	Signature
	 	 	 
	Li Kefeng	 	Wu Longming
	Name	 	Name
	 	 	 
	 	 	 
	Title	Date	 	Title	Date

 

    

    

    

 

EXHIBIT B

FEES

 

Frees for Product and Development:

 

USD$840,000.

 

Fees for Services:

 

USD$360,000.

 

R&D, Service fee: 

 

1) The total project development cost
is 60,000,000 FF, of which the product purchase fee is 42,000,000 FF, and the technical service fee is 18,000,000 FF. This price
is tax-included. “FF”is a cryptocurrency based on ERC 20.

 

2) On the day of completion of the
project acceptance, the Customer guarantees that FF will be on at least one exchange platform for trading. Otherwise, the payment
will be changed into USD 1200000.00

 

3) For the first month of on trading
market, once the average price of FF is lower than USD 0.02 per FF within 30 days, Customer needs to reimburse the price spread
with FF or USD agreed by Developer and customer.

 

The payment method and date: 

 

30% of the total fee should be
paid off within 10 days after success of acceptance testing.

 

60% of the total fee should be
paid off within 10 days after two-month stable operation since the date of acceptance testing.

 

10% of the total fee should be
paid off within 10 days after six-month stable operation since the date of acceptance testing. 

 

		5.3	The designated wallet address by Developer: 

0x02899d84b122749f6a09be19215574db4c4e4200

 

		·	5.4 The designated bank account by Developer: 

 

	 	Name of bank : 	 
	 	Account;	 
	 

    

    

    

 

EXHIBIT C

APPROVED THIRD-PARTY MATERIALS AND APPROVED
OPEN SOURCE COMPONENTS]

 

Third Party Software

 

1 AWS Web Service

2 AliCloud Web Service

3 Google Authenticator

4 Google Tag Manager

5 Google Analytics

6 AKAMAI

7 ZENDESK

8 163dun

9 Welink

10 Jiguang

 

Open Source Software

 

    

    

    

 

EXHIBIT D

DELIVERY, TESTING, AND ACCEPTANCE CRITERIA

 

		1.	DELIVERABLES

 

The deliverables applicable to this Statement
of Work are set forth below. The deliverables will be subject to BGA’s review and acceptance in accordance with Section
5 of the Agreement.

 

	Name of Deliverable	Description	Milestone / Due Date	Acceptance Criteria	
        Acceptance Period

         

        (# days)

         

	Requirement Brochure 	
        E-version

        Full introduction of the platform
	June 10th	Meet the requirements of BGA and e-mail confirm by PM from BGA	3days
	Product prototype files	
        E-version

        prototype illustration of all
function pages
	June 15th	Meet the requirements of BGA and e-mail confirm by PM from BGA	3days
	High fidelity product pics	
        E-version

        High fidelity UI files
	June 15th	Meet the requirements of BGA and e-mail confirm by PM from BGA	3days
	Detailed design description	
        E-version

        Detailed design description
for all functions
	June 30th	Meet the requirements of BGA and e-mail confirm by PM from BGA	3days
	Testing report	
        E-version

        unit test and integration test
	September 10th 	Meet the requirements of BGA and e-mail confirm by PM from BGA	3days
	User manual	
        E-version

        All platform users
	September 15th	Meet the requirements of BGA and e-mail confirm by PM from BGA	3days
	Testing report for platform launch	
        E-version

        Signatures from all testers
for launch test
	September 30th	Meet the requirements of BGA and e-mail confirm by PM from BGA	5days
	Source code	e-version	September 30th	Meet the requirements of BGA and e-mail confirm by PM from BGA	5days
	All technical files 	e-version	September 30th	Meet the requirements of BGA and e-mail confirm by PM from BGA	10days

 

     

    

    

 

EXHIBIT E

SUPPORT SERVICES

 

		1.	HOSTING SERVICES

1.1             
Access Requirements. The Licensed Software should
be accessible worldwide by visitors using all major desktop, mobile app or mobile web clients.

1.2             
Hosting Services. Unicorn’s obligations under
this Agreement will include the following: 

 

 

	#	Service, Function or Responsibility
	Hosting and Availability
	(A) 	Provide and maintain all resources and services required to host the Licensed Software in accordance with the requirements of this Agreement and Industry Standards.
	(B)	Provide notice to BGA of any changes to the Hosting Environment that may have an adverse impact on BGA’s use of the Licensed Software.
	(C)	Provide one production environment and one staging environment
	(D)	Implement and maintain physical access controls for the Hosting Services that comply with Industry Standards.
	(E) 	Use commercially reasonable efforts to make the Licensed Software available and functioning in accordance with its intended use to BGA and End Users on a 24 x 7 basis, 365 days each year, excluding scheduled maintenance windows.
	(F) 	Implement and maintain automated monitoring of Licensed Software availability, response times for transactions on the Licensed Software, and automatic alarming and notification of intrusion activities.
	(G)	Notify BGA and End Users of unavailability of the Licensed Software or material components thereof, and issues with transaction response times as soon as becoming aware of such issues by providing notice through the Licensed Software and notify BGA by telephone of any outages of the Licensed Software.  Notify BGA as soon as availability of the Licensed Software resumes.
	(H)	Provide industry-standard full data backup and recovery for BGA and End User data stored in the Licensed Software and send copies of data to an off-site facility.
	User Access
	(I) 	Provide a process for the establishment of accounts for End Users. 
	(J) 	Provide access to the Licensed Software in the Hosting Environment to BGA and End Users on a 24 x 7 basis, 365 days each year, excluding scheduled maintenance window.

 

    

    

    

 

		2.	OPERATION SUPPORT SERVICES 

 

	#	Service, Function or Responsibility
	Maintenance Services
	(A)	Perform preventive and remedial maintenance on the equipment and software in the Hosting Environment in accordance with Industry Standards to ensure availability of the Licensed Software.
	(B) 	Notify BGA of the maintenance windows for the Licensed Software and in any case schedule maintenance windows during time periods that will minimize impact on End Users’ access to and use of the Licensed Software.  Provide reasonable advanced notice to BGA if any Licensed Software outages are expected to occur during a maintenance window.
	(C)	Provide to BGA all Maintenance Changes for the Licensed Software, and implement such changes only during scheduled maintenance windows, provided that, if a Maintenance Change is comprised of a new version or release of the Licensed Software, implement such Maintenance Change following BGA’s written approval.
	(D) 	Support each version of the Licensed Software in accordance with the Agreement for the duration such version is in use by BGA.
	(E)	Perform testing on all Maintenance Changes prior to providing to BGA or implementing in the production environment. 
	Support Desk
	(F)	Provide multiple channels for BGA and End Users to submit inquiries and report incidents and problems on a 24 x 7 basis, including telephone, website, and email. 
	User Support
	(G)	Respond to and resolve user inquiries regarding the Licensed Software, such as issues with system access, within industry standard time frames. 
	(H)	Provide training on the use and features of the Licensed Software to BGA as reasonably requested.
	Incident Response and Resolution
	(I) 	For all incidents and problems that arise with respect to the Licensed Software, proactively triage and resolve the issue as soon as reasonably practicable (commensurate with the severity of the issue) and in accordance with industry standard time frames. 
	(J)	Notify and update BGA on a periodic basis regarding the status of resolution, with the frequency of such updates commensurate with the severity of the issue.

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00310-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00310-of-00352.parquet"}]]