Document:

MEMORANDUM OF AGREEMENT made the 4th day of June 1998

BETWEEN FIJI PUBLIC SERVICE ASSOCIATION a trade union duly registered under the
Trade Union Act Cap 96 (which together with its successors and assigns is
hereinafter called "the Lessor") of the one part

AND CUL (FIJI) LIMITED a limited liability company having its registered office
at Lautoka (which together with its successors and assigns is hereinafter called
"the Lessee") of the other part

BACKGROUND

A.   The Lessor owns an estate in freehold more particularly described in clause
     1.1 as "the Lessor's Property".

B.   The Lessor is developing the Centre described in clause 1.1 in the position
     on the Lessor's Property shown on the Site Plan referred to in clause 1.1.

C.   The Lessee wishes to lease the Premises described in clause 1. 1 and the
     parties have entered into this agreement to record the basic terms of an
     agreement to lease.

                                        1

<PAGE>

THIS AGREEEMENT WITNESSETH as follows:-

1.0  INTERPRETATION

1.1  In this Agreement unless the context otherwise requires:

     "MONTHLY RENTAL" means the monthly rental payable by the Lessee to the
     Lessor pursuant to the terms of the Lease;

     "THE ARCHITECT" means Larsen Holtom Maybin & Company Limited or such other
     architect retained by the Lessor with the prior written approval of the
     Lessee in respect of the Centre;

     "THE BUILDER" means Fletcher Construction Company (Fiji) Limited or such
     other contractor retained by the Lessor with the prior written approval of
     the Lessee to construct the Centre;

     "THE CENTRE" means the Shopping Centre Complex planned for construction on
     the Lessor's Property as shown on the Site Plan;

     "THE DATE OF PRACTICAL COMPLETION" means the date on which Suva City
     Council provides its Certificate of Completion in writing to the Lessor or
     the date on which possession of the completed Centre is handed over to the
     Lessor by the Builder for the time being constructing the Centre which in
     any event shall not be later than 30 November 1998.

     "THE FITTING OUT PERIOD" means the period fixed in clause 2 of the First
     Schedule;

     "THE LEASE" means the lease agreed pursuant to this Agreement to be entered
     into pursuant to clause 7 in the form annexed hereto in the Second
     Schedule;

                                        2

<PAGE>

     "THE LEASE COMMENCEMENT DATE" means the 28th day after and excluding the
     Date of Practical Completion;

     "THE LESSEE" and "THE LESSOR" includes their respective successors,
     executors, administrators and assigns;

     "THE LESSEE'S WORK" means the works to be carried out in clause 3 of the
     First Schedule;

     "THE LESSOR'S PROPERTY" means the land comprised on Certificate of Title
     No. 24859 being Lot 1 on Deposited Plan No. 6617 and situated at the south
     western part of the land adjacent to Laucala Bay Road, Suva comprising of
     an area slightly in excess of one (1) acre;

     "THE LESSOR'S WORK" means the works to be carried out by the Lessor as set
     out in clause 1 of the First Schedule;

     "THE OUTLINE PLANS" means the outline plans and specifications for the
     Centre attached to First Schedule;

     "THE PLANS" means the full plans and specifications for the Centre to be
     developed in accordance with and based on the Outline Plans pursuant to
     clause 2.1;

     "THE PREMISES" means the supermarket building of approximately 30,0000
     square feet to be constructed on the Lessor's Property and includes the
     adjacent customers' car park;

     "THE SITE PLAN" means the plan of the Lessor's Property showing the
     approximate location of the Centre.

     "THE WARRANTY PERIOD" means six months from the day after the Lessor has
     given vacant possession of the Centre to the Lessee in order for the Lessee
     to carry out the Lessee's work or the date of practical completion
     whichever is the later.

                                        3

<PAGE>

1.2  Where obligations bind more than one person those obligations shall bind
     those persons jointly and severally.

2.0  LESSOR TO COMPLETE BUILDING

2.1  The Lessor shall arrange for the Architect to with due diligence and
     substantially in accordance with and based on the Outline Plans and
     specifications of the premises provided by the Lessee to complete the usual
     detailed plans and specifications required for building permits and
     construction detail.

2.2  The Lessor shall subject to:

     (a)  the provisions of this Agreement; and

     (b)  any delays caused through unavailability of building permits or local
          authority requirements, strikes, lock-outs, weather, acts of God or
          Parliament, or loss by fire, explosion, earthquake or perils or causes
          beyond the reasonable control of the Lessor

     engage the Builder to complete the Centre and the Premises substantially in
     accordance with the Plans by the Date of Practical Completion.

                                        4

<PAGE>

2.3  The Lessor shall at its sole cost and expense arrange with the Builder for
     the construction works to be carried out with all due diligence, in a
     thorough and workmanlike manner and in accordance with normal standard
     trade practices and comply with all lawful conditions imposed by the
     authority issuing the building permit.

2.4  The Lessor shall have no right to carry out and effect any changes to the
     Outline Plans, the Plans and the Premises unless the Lessor obtains in
     writing (prior to the carrying of such changes) from the Lessee a change
     order to the effect which change order shall not be unreasonably withheld.

2.5  If any materials as set out in the specifications are unprocurable or
     subsequently prohibited by any statute, regulation or by-law then the
     Builder may, with the prior written consent signed by the Lessor who shall
     consult the Lessee, substitute any approved equal permissible materials to
     be of a value and quality as near as reasonably practicable with the
     specified materials.

                                        5

<PAGE>

2.6  The Lessor shall:-

     (a)  use reasonable endeavours to ensure that the Date of Practical
          Completion is not later than 30th day of November 1998;

     (b)  keep the Lessee fully informed of any likely change to the estimated
          completion date as construction proceeds; and

     (c)  give as much notice as is reasonably possible of the proposed Date of
          Practical Completion; and

     (d)  obtain all necessary approvals, permits and consent from all relevant
          statutory authorities before commencement of the Lessor's work and
          during each and every stage throughout.

2.7  If the Lessor shall fail to deliver possession of the Shopping Centre
     Complex to the Lessee on or before the date of Practical Completion then
     the Lessor shall pAy to the Lessee the equivalent of the amount that the
     Builder is liable to pay to the Lessor as compensation for each day the
     Builder fails to complete the premises (and if there is no such provision
     then a sum equal to no less than $1,000.00 per

                                        6

<PAGE>

     day) as liquidated damages per day including weekends and public holidays
     between the proposed Date of Practical Completion and the date when the
     Lessor actually delivers possession of the premises.

2.8  If, at any time during the Warranty Period, the Lessor receives from the
     Lessee notice of any failure to comply with warranty set forth in clause
     2.1 and 2.3, the Lessor shall within a reasonable time but no later than 21
     days of the notice and at such times as the Lessee directs, satisfactorily
     correct such noncompliance. All costs incidental to such correction and
     remedy shall be borne by Lessor.

2.9  If, the Lessor fails to satisfactorily correct or remedy any non-compliance
     or damage in accordance with clause 2.8, then the Lessee shall have the
     right, but not the obligation to perform, on behalf and at the expense of
     the Lessor, any correction or remedy which the Lessor has failed to perform
     and of which the Lessee has given the Lessor notice.

                                        7

<PAGE>

3.0  LESSEE'S FIT-OUT WORK

3.1  The Lessee shall upon delivery of possession of the Centre or the premises
     by the Lessor carry out the construction in the Premises of the Lessee's
     Work and other fitting out works reasonably necessary for the purposes of
     Lessee's occupation as set out in clause 3 of the First Schedule hereto.

3.2  To enable the Lessee to have the immediate use and occupation of the
     Premises at the Lease Commencement Date the Lessor shall give to the Lessee
     the Fitting Out Period during which period the Premises will be available
     free of rental for the carrying out by the Lessee of the Lessee's Work and
     any other approved fitting out.

3.3  The Lessor will make the Premises available for occupation by the Lessee
     for the Fitting Out Period commencing on the date notified by the Lessor
     under clause 3.2. During the Fitting Out Period the Lessee shall carry out
     and complete the Lessee's Work and other approved fitting out.

3.4  The Lessee shall not use or occupy the Premises during the Fitting Out
     Period for any purpose

                                        8

<PAGE>

     other than the carrying out of the Lessee's Work and any other approved
     fitting out.

3.5  The Lessee shall:

     (a)  with all due speed carry out and complete the Lessee's Work and other
          approved fitting out in a good and workmanlike manner during the
          Fitting Out Period;

     (b)  complete the interior of the Premises to a high and tasteful standard
          and in accordance with all statutory regulations applicable.

3.6  The Lessee shall immediately upon the expiry of the Fitting Out Period and
     prior to the date for the opening of the Centre remove from the Premises
     and surrounds all rubbish and trade waste so as to leave the Premises and
     surrounds in a clean and tidy condition. If the Lessee fails to comply with
     this requirement the Lessor may attend to such removal and cleaning work
     and recover the full costs of so doing from the Lessee on demand.

3.7  The Premises shall be at the risk of the Lessee from commencement of the
     Fitting Out Period. The Lessee shall during the Fitting

                                        9

<PAGE>

     Out Period effect and maintain in full force in the name of the Lessor and
     the Lessee comprehensive insurance (including contractors all risks and
     public liability) in respect of the Lessee's Work and other approved
     fitting out with an approved insurance company.

3.8  The Lessee shall keep against all claims, the lessor indemnified actions,
     losses and expenses of any nature which the Lessor may suffer or incur or
     for which the Lessor may become liable in respect of the carrying out and
     existence of the Lessee's Work.

4.0  FORCE MAJEURE

4.1  If at any time the Lessor is prevented from fulfilling the Lessor's
     obligations pursuant to this Agreement where such failure is directly or
     indirectly caused by or in any way arises or results from force Majeure
     beyond the Lessor's reasonable control, the Lessor may terminate this
     Agreement by giving written notice to the Lessee accordingly. An act of
     force Majeure shall include by way of example only flood, earthquake, civil
     disturbances, war, war rationing allocation or embargoes,, national strikes
     or labour shortages not peculiar to the Lessor's Property or acts of God or
     government

                                       10

<PAGE>

     or local or regional authorities or any branch or agency of them.

5.0  INSURANCE

5.1  Before work is commenced and during the period of construction and
     extension thereto, the Lessor shall insure the works and upon completion of
     the Centre in the names of the Lessor and the Lessee for their respective
     rights and interests against fire floods lightning storm tempest earthquake
     strikes riots civil commotion malicious damage or action of the State's
     enemies to their full insurable value.

6.0  ACCESS TO LAND

6.1  The Lessee and the agents of the Lessee are entitled at all reasonable
     times to enter upon the land to inspect the Lessor's work.

7.0  AGREEMENT TO ENTER INTO A LEASE

7.1  The Lessor agrees to lease and the Lessee to take on the lease of the
     Premises on the terms set out therein and in accordance with this
     Agreement. Such Lease shall be in the form and contain the terms,
     conditions, covenants and

                                       11

<PAGE>

     provisions of the Lease attached to this Agreement as attached in the
     Second Schedule hereto.

7.2  The Lessee will execute such Lease and redeliver to the Lessor within 30
     days of receipt of the Lease by the Lessee or the Lessee's Solicitors.

7.3  Until the Lease has been executed and delivered to the Lessor the parties
     shall be bound by the terms, covenants and conditions contained in this
     Agreement.

7.4  The Lessee shall be permitted to lodge a Caveat on the Lessor's Property
     any time after the execution of this Agreement to protect its interest as a
     Lessee only PROVIDED HOWEVER that the Lessee shall withdraw its Caveat at
     the written request or on the application of the Lessor on the condition
     precedent that the Lessor procures the execution of the deed (to which it
     will also be a party) by the relevant financial institution from which the
     Lessor intends to obtain financial assistance for the purposes of
     construction of the premises herein that the financial institution as
     mortgagee along with its successors and assigns will not exercise any of
     its rights as mortgagee

                                       12

<PAGE>

     including (but not limited to) its powers of sale whereby the Lessee would
     or may be deprived of any of its rights under the Lease or suffers any loss
     or damage on account of such exercise AND IT IS FURTHER PROVIDED that the
     Lessor will after the registration of the said mortgage undertake to
     register with the Registrar of Titles the Lease giving the Lessee an
     overall second priority ranking over the Lessor's property and until the
     Lease is registered as aforesaid the Lessor acknowledges that the Lessee is
     entitled to register another caveat to protect its interest as Lessee over
     the Lessor's property.

8.0  PREMISES

8.1  The rentable areas of the Premises shall be subject to final measurement by
     the Architect whose calculations of area shall be final and binding on both
     parties.

8.2  The rental area shall not be less than 30,000 sq feet.

                                       13

<PAGE>

9.0  ARBITRATION

9.1  If any dispute or difference shall arise between the parties as to:

     (a)  the meaning or application of any part of this Agreement; or

     (b)  concerning any other matter arising from this Agreement for the
          proposed lease

     the dispute or difference ("the Issue") shall be referred to the award of a
     single arbitrator to be agreed upon between the Lessor and the Lessee.

9.2  If the Lessor and the Lessee are unable to agree upon a single arbitrator
     within 10 days of either notifying the other in writing of their wish to
     have the Issue arbitrated then either party ("the Notifying Party") may at
     any time subsequently by notice in writing to the other party ("the
     Receiving Party") require the Issue to be determined by two arbitrators
     (one to be appointed by the Lessor and one to be appointed by the Lessee)
     and their umpire (to be appointed by the arbitrators before proceeding to
     determine the Issue). The notice

                                       14

<PAGE>

     to be given by the Notifying Party Pursuant to this clause shall:

     (a)  nominate the arbitrator appointed by the Notifying Party; and

     (b)  require the Receiving Party to nominate their arbitrator by a date not
          less than 10 days after the date of service of the notice by the
          Receiving Party; and

     (c)  warn the Receiving Party of the consequences under clause 10.3 of
          failure to appoint an arbitrator by the date specified by the
          Notifying Party.

9.3  If the Receiving Party shall fail to appoint their arbitrator by the date
     specified then the Notifying Party may by notice in writing to the
     Receiving Party have the Issue determined solely by the Notifying Party's
     arbitrator.

9.4  If any arbitrator appointed pursuant to clauses 9.1 and 9.2 refuses or
     fails to act in pursuance of the arbitration (including appointing an
     umpire if necessary) within a reasonable time of their appointment then
     either the Lessor or the Lessee may (provided the defaulting arbitrator has
     first been given

                                       15

<PAGE>

     in writing a reasonable time in which request the President of the Fiji Law
     to act) Society to appoint a replacement arbitrator or an umpire (if the
     arbitrators are unable to agree on an umpire) who shall act in lieu of the
     defaulting arbitrator or as the umpire as the case may be.

9.5  Time shall be of the essence under clauses 9.1 to 9.4 (inclusive).

9.6  The parties agree to be bound by any decision or award completed pursuant
     to clauses 9.1 to 9.8 (inclusive).

9.7  This provision shall survive the expiration or earlier determination of
     this Agreement and the commencement, execution, expiration or earlier
     determination of the Lease.

9.8  A referral to arbitration under clause 9.1 shall be a submission to
     arbitration under the Arbitration Act and the provisions of that Act shall,
     to the extent they re not inconsistent with anything in clauses 9.1 to 9.7
     (inclusive), apply.

                                       16

<PAGE>

10.0 ASSIGNMENT

10.1 The Lessee shall have the right to assign this Agreement provided it
     obtains the prior consent of the Lessor which consent shall not be
     unreasonably withheld where the proposed assignee is financially sound,
     reputable and reliable and is able to provide a similar bank bond in
     respect of the Lease.

11.0 CONSENT

11.1 The Lessor will do all things necessary and incidental to obtain the
     written consent of the Minister of Lands to the Lease contemplated herein.
     Such written consent shall be obtained by the Lessor on or before the
     beginning of the Fitting Out Period.

12.0 SIGNS

12.1 The Lessee shall, at its sole cost and expense, lawfully erect signs
     concerning the business of the Lessee or displaying the Lessee's name on
     the parking area and building of the demised premises, and the roof
     thereof, if permitted by local regulations, by the date of completion

                                       17

<PAGE>

     and the Lessee agrees to maintain the said signs in good state of repair.

13.0 THE OBLIGATIONS

13.1 The obligation of the Lessee herein shall not merge upon the completion of
     the Lessor's Work herein but shall continue to be binding.

15.0 NOTICES

15.1 All notices required hereunder shall be in writing and may be personally
     delivered or mailed by certified or registered mail, addressed to the
     respective parties, and all notices, demands or other writing to be made,
     given or sent hereunder, or which may be so given or made or sent by any
     party to the other shall be deemed to have been fully given or made when
     personally delivered or if mailed, 3 calendar days following the deposit
     thereof at the Post Office, registered or certified, postage prepaid, and
     addressed to the respective parties as follows:-

     Lessor:   The Secretary,
               FIJI PUBLIC SERVICES ASSOCIATION,
               G.P.O. Box 1405,
               Suva, Fiji.
               Tel : 311662
               Fax : 301099
               Attn: Mr. Mahendra Chaudhary

                                       18

<PAGE>

     Lessee:   The Managing Director,
               CUL (FIJI) LIMITED,
               P.O. Box 7,
               Nadi, Fiji.
               Tel : 722670
               Fax : 720080
               Attn: Mr. Terence Buckley

15.0 COST

15.1 EACH party shall bear its own Solicitors cost in preparing and attending to
     execution of this Agreement and the Lease except that the Lessee shall pay
     disbursements for the stamping of the same.

16.0 PROVISO

16.1 This Agreement and the proposed Lease is subject to the consent of the
     Minister of Lands pursuant to Section 6 of the Land Sales Act and also
     subject to the Lessor entering into a written contract for construction of
     the premises with the Builder.

16.2 The Lessee shall be required on execution hereof to provide to the Lessor
     copies of all relevant consents and approvals from the Minister of Finance,
     Reserve Bank of Fiji and Trade and Investments Board concerning its right
     to carry on business in Fiji.

                                       19

<PAGE>

                                 FIRST SCHEDULE

                            LESSOR AND LESSEES' WORK

1.   THE LESSOR'S WORK

     The Lessor shall carry out all works to construct the Centre and the
     premises be completed substantially in accordance with the Site Plans, the
     Outline Plans and the Plans, specifications and calculations provided by
     the Architect and the Builder as per Site Plans attached hereto.

2.   FITTING OUT PERIOD

     The Fitting Out Period shall be a period of 28 days prior to the Lease
     Commencement Date.

3.   LESSEE'S WORKS

     The Lessee shall carry out all works to be completed substantially in
     accordance with the Plans and will provide at the Lessee's own cost:

     (i)   installation of Refrigeration equipment (excluding electrical to main
           panel which is Lessor's responsibility);

     (ii)  installation of steel-racks and shelving;

                                       20

<PAGE>

     (iii) Computers,Cash Registers and Counters;

     (iv)  Office Equipment & Furniture.

     (v)   Sign Boards, internal partitions, offices and storerooms.

                                       21

<PAGE>

                           [MAP OF SITE APPEARS HERE]

<PAGE>

                           [MAP OF SITE APPEARS HERE]

<PAGE>

                                 SECOND SCHEDULE

                                      FIJI

                                      LEASE

FIJI PUBLIC SERVICE ASSOCIATION a trade union duly registered under the Trade
Union Act (Cap 96) (hereinafter called "the Lessor") hereby leases to CUL (FIJI)
LIMITED a limited liability company having its registered office at Lautoka
(hereinafter called "the Lessee") to be held by the Lessee as tenant for the
period of ten (10) years commencing no later than the 1st day of January 1999 or
if consent of the Minister of Lands is not obtained by that day then the 1st day
of the 1st month following the date of the Minister of Land's consent at the
monthly rental of $30,850.00 (thirty thousand eight hundred and fifty dollars)
per month plus VAT payable on the 1st day of each and every month at the times
and in the manner hereinafter provided for the initial period of 5 years and
thereafter at a Fair Market Value rent to be agreed between the Lessor and the
Lessee for the next 5 years which rent is to be determined in accordance with
the procedure set out in clause 4 hereof if no agreement is reached the Lessor
and the Lessee which rent in any event shall not be less than $30,850.00 per
month TOGETHER WITH ALL THAT improvement by way of a supermarket complex
(comprising a floor area of not less than 30,000 square feet) with car-park
space for 90 vehicles constructed by the Lessor pursuant to an Agreement dated
____ day of _________, 1998 between the Lessor and Lessee situated on the south
western part of the freehold land situated at Laucala Bay Road, Suva hereinafter
referred to as "the demised premises" and identified in the Schedule hereto ON
ALL THAT OR PARCEL OF LAND described as follows:-

<TABLE>
<CAPTION>
                                                                                           Area
Title Number             Description           Island                City                 A R P
- -------------------------------------------------------------------------------------------------------
<S>                      <C>                   <C>                   <C>           <C>
                           Lot 1 on                                                Slightly in excess
C. T. 24859              DP No. 6617           Vitilevu              Suva               of 1 acre
- -------------------------------------------------------------------------------------------------------
</TABLE>

______________________________________________  Lodged by:  YOUNG & ASSOCIATES,
                                                            SOLICITORS,
___________________   No. ________________                  LAUTOKA. FIJI.

Registered __________ at _________________

           _______________________________      Date ______________________
                  Registrar of Titles
                                                Documents: ________________

                                       24

<PAGE>

This Lease is subject to the following conditions, restrictions and covenants:

1.   THE Lessee hereby agrees with the Lessor as follows: -

     (a)  To pay the reserved rent Plus VAT in Suva to the Lessor or to such
          agent as it shall from time to time in writing direct;

     (b)  To pay promptly all apportioned (according to the area utilized) Suva
          City Council rates, garbage fees, charges for electricity and water
          consumed on the demised premises and not to commit or permit any act
          or omission whereby the water or electricity supply shall be or become
          liable to be disconnected;

     (c)  Subject to paragraph 3(h) hereof from time to time and at all times
          throughout the said term to uphold and maintain in good and tenantable
          repair the interior of the walls floors and ceilings but not if it
          relates to structural aspect thereof of the demised premises and the
          windows doors locks and fastenings thereof and (but without prejudice
          to the Lessee's obligations under paragraph (d) of this clause) the
          electrical water and sewerage installations therein and all the
          Lessor's fittings and fixtures in connection therewith (fair wear and
          tear and damage by fire storm earthquake or inevitable accident or
          strikes and riots or civil commotion or action of the States enemies
          (without neglect or wilful default of the Lessee) alone excepted and
          at the expiry or sooner determination of the said term to deliver up
          to the Lessor the demised premises in and tenantable repair save only
          as aforesaid;

     (d)  At the expense of the Lessee to replace or repair all defective or
          broken circuit fuses, wall switches and lampholders in the electricity
          installations of the demised premises, promptly renew the washers or
          any leaking taps in the demised premises and repair and replace all
          broken glass including exterior windows in the premises;

     (e)  Not to throw or permit to be thrown any rubbish or other substances or
          things out of any windows or doors of the demised premises or in or
          about other parts of the said building to which the Lessee shall have
          access or into any water closet or other water supply apparatus of the
          demised premises and not to do or permit any act whereby the exterior
          walls of the demised premises shall be discolored defaced or damaged;

     (f)  To duly and promptly comply with all lawful notices and requirements
          of the relevant City Council; Medical; Health and other proper Public
          Authorities relating to the demised premises in respect of matters
          arising from the Lessee's neglect or default;

     (g)  (i)  Not at any time to do or suffer any act or omission upon or about
          the demised premises which may render any increased or extra premium
          payable for the insurance of the said building against loss or damage
          by fire or which may make void or voidable any policy for such
          insurance;

          (ii) To keep the Lessor indemnified against all claims, actions,
          losses and expenses of any nature which the Lessor may suffer or incur
          or for which the Lessor may become liable in respect of:

                                       25

<PAGE>

          (1)  The neglect or careless use or misuse by the Lessee or persons
               under the control of the Lessee of the demised premises or
               arising out of any faulty fixture or fitting of the Lessee;

          (2)  Any accident or damage to property or any person arising from any
               occurrence in or near the demised premises wholly or in part by
               reason of any act or omission by the Lessee or persons under the
               control of the Lessee;

     (h)  Not to suffer or permit any person or persons to carry out or permit
          to be carried on in or upon the demised premises any noise or
          offensive or immoral business trade calling or purpose nor create any
          nuisance thereon or do or suffer to be done any act matter or thing
          which shall or may be or may grow to the annoyance nuisance grievance
          damage or disturbance of the Lessor or occupiers of any adjoining
          lands or premises;

     (i)  To permit the Lessor or its servants agents contractors or workmen at
          all reasonable times and on giving notice to the Lessee to enter into
          and upon the demised premises to view the state and condition thereof
          or for the purpose of executing repairs or renovations thereto or to
          any other part of the building of which the demised premises form part
          provided however that the Lessor its servants agents contractors or
          workmen shall not enter any strong-room cage or place in the demised
          premises where money securities or documents are kept unless
          accompanied by an officer of the Lessee and that the Lessor will use
          all reasonable endeavors to ensure that any repair or renovation work
          shall be carried out in a manner which will not unduly interfere with
          the Lessee's business;

     (j)  The Lessee will not without the consent in writing of the Lessor bring
          upon the demised premises any machinery or plant or equipment unless
          reasonably necessary or proper for the conduct of the Lessees use of
          the demised premises as herein provided and in no event shall any such
          machinery plant or equipment be of such nature or size as to cause or
          in the reasonable opinion of the Lessor be likely to cause any
          structural or other damage to the floors or walls or any other parts
          of the demised premises or the common parts. Before bringing any such
          equipment upon the demised premises, or the common parts the Lessee
          shall inform the Lessor of the Lessee's intention so to do and the
          Lessor may direct the routing installation and location of all such
          machinery plant and equipment and the Lessee shall observe and comply
          with all such directions PROVIDED HOWEVER the Lessor acknowledges that
          not withstanding the foregoing, it will and does permit the Lessee to
          use heavy duty fork lifts on the demised premises or the common parts
          in the normal course of business;

     (k)  The Lessee will not use or permit to be used the premises or any part
          thereof otherwise then as a supermarket;

     (l)  The Lessee will not assign transfer demise sublet or part with or
          share the possession of or grant any license affecting or otherwise
          deal with or dispose of the demised premises or any part thereof or
          any act or deed procure the demised premises or any part thereof to be
          assigned transferred demised sublet shared or put into the possession
          of any person or persons without the consent in writing of the Lessor
          first had and

                                       26

<PAGE>

          obtained which consent shall not be reasonably or arbitrarily withheld
          where the assignee or sub-lessee is financially sound reputable and
          reliable and is able to provide a similar bank bond in respect of this
          Lease as set out in clause 13 hereof.

2.   THE Lessor hereby agrees with the lessee as follows:-

     (a)  Except as expressly made payable by the Lessee to duly and punctually
          pay all insurance premiums and other assessments and charges levied
          charged or imposed on the Lessor's said land and/or the building
          thereon or on the Lessor or occupier thereof in respect thereof;

     (b)  The Lessee paying the rent hereby reserved and observing and
          performing all and singular the agreements and stipulations on the
          Lessee's part herein contained or implied shall peaceably hold and
          enjoy the demised premises during the said term of years without any
          interruption by the Lessor or any person rightfully claiming under or
          in trust for the Lessor;

     (c)  The Lessor will keep in good and tenantable repair and condition the
          buildings on the demised premises so that the Lessee shall have the
          full and free use and benefit thereof and the demised premises and
          without limiting the generality of the foregoing the Lessor will at
          all times maintain in good condition and proper working order the
          water electrical sewerage and drainage installation in or serving the
          said buildings or the demised premises except in the case of a defect
          occasioned by the negligence or default of the Lessee;

     (d)  The Lessee may at its option and at its own cost, paint the interior
          or exterior of the demised premises or any part thereof during the
          currency of the Lease;

     (e)  The Lessor will insure and keep insured during the currency of this
          Lease all buildings on the demised premises for their full replacement
          value against all risks including (but not limited to) fire, malicious
          damage, hurricane and earthquake and shall apply all or any proceeds
          received under any policy of insurance towards reinstatement or repair
          of the buildings or any part thereof as hereafter provided.

3.   IT is hereby agreed and declared by and between the parties hereto as
follows:-

     (a)  If the demised premises or any part thereof shall at any time during
          the continuance of this lease be partially destroyed or damaged by
          fire floods lighting storm tempest earthquake strikes riots civil
          commotion or action of the State's enemies but not to such an extent
          as to render the same unfit for the occupation and use of the Lessee
          then the Lessor will at Lessor's expense forthwith and with all
          reasonable speed reinstate the same and a fair and just proportion of
          the rent hereby reserved according to the nature and extent of the
          damage sustained shall be suspended and cease to be payable until the
          premises shall have been reinstated and made fit for the occupation
          and use of the Lessee and in the case of any dispute arising as to the
          amount of such abatement of rent the same shall be referred to
          arbitration under the provisions of the Arbitration Act;

                                       27

<PAGE>

     (b)  In case the demised premises shall be destroyed or damaged by fire
          flood lightning storm tempest earthquake strikes riots civil commotion
          or action of the State's enemies to such an extent as to render the
          same wholly untenantable or if through the lawful act of any public
          authority the Lessee shall be deprived of the use and enjoyment of the
          demised premises then at the absolute option of the Lessee to be
          exercised in writing the Lease hereby created may immediately cease
          and determine but without prejudice to the rights of either party in
          respect of any antecedent breach or non-observance of any covenant or
          provisions hereof. If the Lessee does not so exercise the lessee right
          to determine this Lease within (6) six months from the date of
          entitlement or if it earlier notifies the Lessor of its desire not to
          so determine the Lease then this Lease shall continue for the
          remaining term and any renewal hereby granted in respect of the
          demised term premises. In that event the Lessee shall be entitled to
          construct such new building as it shall decide and the Lessor will
          apply or cause to be applied insurance proceeds received by or for it
          towards such cost of construction;

     (c)  If the whole of the demised Premises, or if such portions of the
          facilities and building improvements comprising part of the demised
          Premises as may be required for the reasonable use of the Lessee's
          business, shall be taken by virtue of any condemnation or eminent
          domain proceeding, this Lease, at the option of the Lessee, shall
          automatically terminate as of the date of any final judgment entered
          under such condemnation, or as of the date possession is taken by the
          condemning authority, whichever is earlier. In the event the Lessee
          does not exercise such right to terminate this lease, this Lease shall
          continue and the Lessee shall continue in possession of the remainder
          of the demised Premises under the terms herein provided, except that
          the monthly rent payable herein shall be reduced in proportion to the
          amount of the land area of the demised Premises so taken. The Lessee
          shall have the right to recover from any condemning authority that
          portion of any award attributed to the Lessee's leasehold interest;

     (d)  If and whenever the rent shall be in arrear and unpaid for twenty (21)
          days from the due date the same may be levied by distress;

     (e)  Without prejudice to the rights power and remedies of the Lessor
          otherwise under this Agreement the Lessee will pay to the Lessor
          interest at the rate of 13.5% per annum on any moneys including rent
          due but unpaid for seven (7) days by the Lessee to the Lessor on any
          account whatsoever pursuant to this Agreement such interest to be
          computed from the due date for the payment of the moneys in respect of
          which the interest is chargeable until payment of such moneys in full
          and to be recoverable in like manner as rent in arrears;

     (f)  If the rent hereby reserved or any part thereof shall be in arrear and
          unpaid for the space of twenty-eight (28) days whether the same shall
          have been legally or formally demanded or not or if and whenever there
          shall be any breach or non-observance or non-performance of any
          stipulation condition or agreement herein on the part of the Lessee
          contained or implied it shall be lawful for the Lessor forthwith or at
          any time thereafter without making any demand or giving any notice or
          doing or seeing to the doing of any act matter or thing to re-enter
          upon and take possession of the demised

                                       28

<PAGE>

          premises or any part thereof in the name of the whole whereupon the
          term hereby created shall absolutely cease any rent due or accruing
          due hereunder or from liability for any antecedent breach of any
          stipulation agreement or condition hereunder;

     (g)  That no waiver by the Lessor of one breach of any covenant obligation
          or provision in this Lease contained or implied shall operate as a
          waiver of another breach of the same or of any other covenant
          obligation or provision in this Agreement contained or implied;

     (h)  In the event of the Lessee holding over after the expiration or sooner
          determination of the term hereby granted or any lawful renewal thereof
          with the consent of the Lessor the Lessee shall become a monthly
          Lessee only of the Lessor at a monthly rental equivalent to a monthly
          rent payable by the Lessee hereunder after the expiration or sooner
          determination of such term or renewal thereof and otherwise on the
          said terms and conditions mutatis mutandis as those herein contained
          so far as applicable;

     (i)  The Lessee may prior to the commencement of the said term and from
          time to time during the said term and at its discretion make erect or
          install alterations additions decorations improvements fixtures
          fittings and appliances within the existing building on the demised
          premises for the purpose of its business and such shall remain the
          property of the Lessee and upon the expiration or earlier termination
          of this Lease, the Lessee may remove the same provided that it makes
          good any damage to the Lessor's premises occasioned by such removal.

4.   AS long as the Lessee is not in default under this Lease, the Lessee shall
have the option to renew the term of this Lease for two renewal terms (each, a
"Renewal Term") of five (5) years provided the Lessee gives to the Lessor at
least nine (9) months notice of its intention to renew the Lease such renewal to
be upon the covenants, terms and conditions as set forth in this Lease, except
that annual rent for such Renewal Term will be the "Fair Market Rental Value"
(defined below) of the Premises at the commencement of the Renewal Term but in
any event the annual rent shall not be less than the rent for the previous term.
In order to exercise its option to renew, Lessee shall give written notice to
Lessor not less that one (1) year prior to the end of the then-current lease
term.

"Fair Market Rental Value" shall be determined as follows: Lessor and Lessee
shall seek to agree as to Fair Market Value within thirty (30) days after Lessee
gives Lessor notice of its election to renew this Lease. If Lessor and Lessee do
not agree about Fair Market Rental Value within such thirty (30) day period, the
following provisions shall apply:

     (a)  Within fifteen (15) days after the expiration of the thirty (30) day
          period, the Lessor and Lessee shall each identify an impartial,
          licensed real estate professional familiar to

                                       29

<PAGE>

          the Suva area to act as a valuation expert. If either party fails to
          appoint an expert within such fifteen (15) day period, then the
          determination of the expert first appointed will be final, conclusive
          and binding on both parties.

     (b)  The named experts shall together determine the Fair Market Rental
          Value. In making such determination, the experts shall consider the
          rentals at which leases are being concluded for comparable space in
          the Building and for comparable space in comparable buildings. If the
          experts fail to agree on the Fair Market Rental Value within thirty
          (30) days of their appointment and the difference in their conclusions
          about Fair Market Rental Value is (10%) or less of the lower of the
          two determinations. Fair Market Rental Value shall be the average of
          the two determinations.

     (c)  If the two experts fail to agree on Fair Market Rental Value and the
          difference between the two determinations exceeds ten percent (10%) of
          the lower of the two determinations then the experts shall appoint a
          third expert, similarly impartial and qualified, to determine the Fair
          Market Rental Value. This third expert shall determine the Fair Market
          Rental Value within thirty (30) days of his or her appointment, and
          his or her determination will be final, conclusive and binding on
          Lessor and Lessee. The Lessor and Lessee shall each execute and
          deliver an agreement confirming annual rent for the renewal term.

     (d)  The Lessor and the Lessee shall each pay the fees of any expert
          appointed by the Lessor and Lessee, respectively, and Lessor and
          Lessee shall each pay one-half (1/2) of the fees of the third expert,
          if any.

5.   IN consideration of the sum of $1.00 (One dollar) paid to the Lessor by the
Lessee (the receipt of which sum the Lessor hereby acknowledges) the Lessor
agrees and undertakes that if at any time during the term of this Lease or any
renewal thereof the Lessor shall decide to sell the property comprised in
Certificate of Title No. 24859 then the said property shall be first offered in
writing to the Lessee. The said offer shall be at a price and upon the terms and
conditions as the Lessor shall advise and the offer shall remain open for
acceptance by the Lessee for such period as shall be stipulated being not less
than one month from the date of the service of the offer upon the Lessee. Upon
receipt of

                                       30

<PAGE>

the said offer the Lessee may cause a valuation to be done at its cost of the
property by a qualified registered valuer in Fiji appointed mutually by the
parties or failing agreement by the firm. Such valuation shall be used by the
parties as a basis for negotiating an acceptance of the said offer or any other
price that may be mutually agreed. Should the parties fail to mutually agree
upon a price or should the Lessee refuse to accept the said offer or fail to do
so within the stipulated time then the Lessor shall be free to sell the said
property to anyone else but such sale shall not be at a price lower nor the
terms and conditions any less onerous than those already offered to the Lessee.
In any event the cost of the said valuation shall be shared equally by the
Lessor and the Lessee.

6.   THIS Lease is subject to the consent of Minister of Lands pursuant to the
provisions of Section 6 of the Lands Sales Act. The Lessor shall obtain such
consent before the execution of this Lease.

7.   (a)  THE Lessee shall pay all Value Added Tax (or any similar tax levied in
          substitution therefore) on all payments by the Lessee in terms of this
          Lease where such payments are levied with such tax.

     (b)  THE Lessee shall upon demand pay to the Lessor all Value Added Tax (or
          Any similar tax levied in substitution therefore) paid or payable by
          the Lessor in respect of:

          (i)   the rental payable under this Lease;

          (ii)  any other payments paid or payable by the Lessee under this
                Lease or paid by the Lessor on behalf of the Lessee in terms of
                the Lessee's obligations to make such payment under this Lease.

8.   (a)  IF any dispute or difference shall arise between the parties as to:

          (i)   The meaning or application of any part of this Lease; or

          (ii)  Any other matter in connection with or which may have an effect
                on this Lease

     the dispute or difference ("the Issue") shall be referred to the award of a
     single arbitrator to be agreed upon between the Lessor and the Lessee.

     (b)  If the Lessor and the Lessee are unable to agree upon a single
          arbitrator within 10 days of either the Lessor or the Lessee notifying
          the other in writing of their wish to

                                       31

<PAGE>

          have the Issue arbitrated then either party ("the Notifying Party")
          may at any time subsequently by notice in writing to the other party
          ("the Receiving Party") required the Issue to be determined by two
          arbitrators (one to be appointed by the Lessor and one to be appointed
          by the Lessee) and their umpire (to be appointed by the arbitrators
          before proceeding to determine the Issue). The notice to be given by
          the Notifying Party pursuant to this subclause shall:

          (i)   Nominate the arbitrator appointed by the Notifying Party; and

          (ii)  Require the Receiving Party to nominate its arbitrator by a date
                not less than 10 days after the date of service of the notice on
                the Receiving Party; and

          (iii) Warn the Receiving Party of the consequences under subclause 8
                (c) of failure to appoint an arbitrator by the date specified by
                the Notifying Party.

     (c)  If the Receiving Party shall fail to appoint its arbitrator by the
          date specified then the Notifying Party may by notice in writing to
          the Receiving Party have the Issue determined solely by the Notifying
          Party's arbitrator.

     (d)  If any arbitrator appointed pursuant to subclauses 8 (a) or (b)
          refuses or fails to act in pursuance of the arbitration (including
          appointing an umpire if necessary) within a reasonable time of their
          appointment then either the Lessor or the Lessee may (provided the
          defaulting arbitrator has first been given in writing a reasonable
          time in which to act) request the President of the Fiji Law Society to
          appoint a replacement arbitrator or an umpire (if the arbitrators are
          unable to agree on an umpire) who shall act in lieu of the defaulting
          arbitrator or as the umpire as the case may be.

     (e)  Time shall be of the essence under this clause.

     (f)  The parties agree to be bound by any decision or award completed
          pursuant to this clause.

     (g)  This provision shall survive the expiration or earlier determination
          of this Lease.

                                       32

<PAGE>

     (h)  Any referral to arbitration under this clause shall be a submission to
          arbitration under the Arbitration Act Cap 38 which Act shall, to the
          extent not inconsistent with anything in this clause, apply to any
          such submission.

10.  ALL notices required hereunder shall be in writing and may be personally
delivered or mailed by certified or registered mail, addressed to the respective
parties, and all notices, demands or other writing to be made, given or sent
hereunder, or which may be so given or made or sent by any party to the other
shall be deemed to have been fully given or made when personally delivered or if
mailed, 3 calendar days following the deposit thereof in the Fiji mail,
registered or certified, postage prepaid, and addressed to the respective
parties as follows:-

     Lessor:   The Secretary,
               FIJI PUBLIC SERVICES ASSOCIATION,
               G.P.O. Box 1405,
               Suva, Fiji.
               Tel: 311662
               Fax: 301099
               Attn: Mr. Mahendra Chaudhary

     Lessee:   The Managing Director,
               CUL (FIJI) LIMITED,
               P.O. Box 7,
               Nadi, Fiji.
               Tel: 722670
               Fax: 720080
               Attn: Mr. Terence Buckley

11.  EACH party shall bear its own Solicitors cost in preparing and attending to
execution of this Lease except that the Lessee shall pay disbursements for the
stamping and registration of the same.

12.  THIS Lease shall be governed by the laws of Fiji.

13.  IN consideration of this Lease the Lessee shall arrange with a Bank in Fiji
on execution hereof to give to the Lessor a Bank Bond in the sum of $180,000.00
for the first 5 years as security for the due observance and performance by the
Lessee of the conditions and stipulations hereinbefore contained and on its part
to be observed and performed. The Bank Bond shall be reduced by $30,000.00 per
completed year after completion of 5 years of the Lease until it is reduced to
$90,000.00 on completion of the eighth year of the lease when it shall be
maintained at $90,000.00 for

                                       33

<PAGE>

the balance of the term and the said Bank Bond will apply to any renewal of the
term in accordance with clause 4 hereof.

AND IT ITS EXPRESSILY DECLARED AND AGREED by the Lessee that the said Bank Bond
shall be provided to the Lessor until expiration of the term of this Lease and
that the Lessor shall be entitled to the proceeds of the Bank Bond or part
thereof in the event any rent monies is owing or any loss or damage is sustained
to the Lessor by reason of the non-fulfillment or non-observance of any of the
terms and covenants herein to be performed by the Lessee.

PROVIDED HOWEVER at the expiration or earlier lawful termination of the Lease,
the Lessor shall be entitled to the proceeds of the Bank Bond held hereunder.

IN WITNESS WHEREOF the parties have subscribed their names the day and year
hereinbefore appearing.

THE COMMON SEAL of FIJI PUBLIC             )
SERVICE ASSOCIATION was hereunto           )
affixed by direction of the Council        )
of the Association in the presence of      )
A. BATISARESAR the President and           )
M.P. CHAUDHARY the General                 )      [Seal]
Secretary of the Association and who       )
certify that they are the proper officers  )
by whom and in whose presence the          )
Seal is to be affixed:                     )

     /s/ A. Batisaresar                            /s/ M.P. Chaudhary
-------------------------------------         ----------------------------------
President                                     General Secretary

THE COMMON SEAL of CUL (FIJI)              )
LIMITED was hereunto affixed in our        )
presence and we certify that we are the    )      [Seal]
proper officers by whom and in whose       )
presence the said Seal is to be affixed:   )

     /s/ Michael J. Rose                           /s/  Allan Youngberg
-------------------------------------         ----------------------------------
Director                                      Secretary

                                       34AMENDMENT TO LEASE

     The Lease, dated October 22, 2001 entered into between TONKO REYES, INC. a
Guam corporation, of 562 Harmon Loop Road, Suite B-9A, Dededo, Guam 96929
("Lessor") and COST-U-LESS, INC., a Washington Corporation of 8160 304th Avenue,
S.E., Building 3, Suite A, Preston, WA ("Lessee") is hereby amended as follows:

     1.   Section 1(a), Premises, of the Lease is partially amended such that
          the premises are now described as follows:

               The Tonko Reyes, Inc. commercial building, commonly know as the
               COST-U-LESS Center ("Center") fronting Harmon Loop Road,
               consisting of an area of 36,000 square feet on the first floor,
               plus an area of 673 square feet on the second floor (mezzanine
               floor space), and the loading dock area of 2,100 square feet for
               a total of 38,773 square feet, all located on Lot No.
               5012-1NEW-1, Dededo, Guam, as shown on Exhibit "A" attached
               hereto.

     2.   Section 2, Term, of the Lease is partially amended such that the
          expiration date of the Lease is extended from May 31, 2012 to May 31,
          2017, which extends the term for 10 years to 15 years.

     3.   Section 3, Rent, of the Lease is deleted in its entirety and replaced
          with the following as follows.

     RENT:

     Lessee shall pay the following amounts to Lessor, in advance, on the first
day of each calendar month, for the term of this Lease, over and above the
common area expenses and other charges allocable to Lessee as stated herein,
without deduction, set-off, prior notice or demand (except as otherwise
specifically set forth herein):

<PAGE>

     Commencement Date to 05/31/2004   $1.20 s.f. per month
     06/01/2004 to 09/30/2006          $1.35 s.f. ($52,343.55) per month
     10/01/2006 to 09/30/2009          $1.40 s.f. ($54,282.20) per month
     10/01/2009 to 09/30/2016          $1.45 s.f. ($56,220.85) per month
     10/01/2016 to 05/31/2017          $1.50 s.f. ($58,159.50) per month

     Said rent shall be paid at Lessor's address, or such other place as may be
designated in writing by Lessor. If the date of commencement, expiration or
termination of the term of this Lease occurs on a day other than the first or
last day of a calendar month, the rent and all other amounts payable by Lessee
hereunder for that month shall be prorated.

     Lessee shall have no options under this Lease.

     4.   The last sentence of Section 7(e) of the Lease is partially amended to
          read as follows:

               Lessee's current proportionate share is 100%.

     5.   The last sentence of Section 7(f)(iv) Common Area Expenses, is amended
          to read as follows:

          At Lessee's option, and upon written approval by Lessor of the terms
          of the coverage, in lieu of paying the common area expense there for,
          Lessee may insure the entire Center with its blanket insurance
          coverage against fire, earthquake, typhoon, flooding and other hazards
          with extended coverage, vandalism, theft and general public liability
          to cover replacement costs and code compliance without policy
          deductibles, policy exclusions or depreciation; with the Lessor as an
          additional named insured and the Bank of Hawaii or any other financial
          institution designated by Lessee as Loss Payee.

          Lessee shall also insure under its Business Interruption insurance
          coverage the payment of rent when the premises is being reconstructed
          or repaired pursuant to Section 6 herein.

     6.   Section 12(a) of the Lease is deleted in its entirety and replaced
          with the following:

     Destruction of Premises:

     (a)  If the partial or total damage or destruction of the premises occurs
          during the term of this Lease, Lessor, at Lessor's option, may
          terminate this Lease if Lessor determines at its sole discretion that
          such repairs would be uneconomical. Further, in the event of any
          partial or total damage or

<PAGE>

          destruction of the premises at any time during the term of this Lease,
          Lessee shall have the right to terminate this Lease, at Lessee's
          option, if the repair or restoration of the premises is expected to
          require, or does require, longer than nine (9) months. If this Lease
          is not terminated pursuant to the foregoing, Lessor must diligently
          repair the damage and restore the premises to their previous condition
          at Lessor's cost, in compliance with all applicable laws, regulations,
          rules and ordinances, as soon as reasonably possible. Except in the
          event of intentional misconduct of Lessor, Lessor's agents, employees,
          and/or contractors, Lessee hereby waives any and all claims for
          damages against Lessor resulting from the destruction of the premises,
          or of Lessee's property.

     7.   All the remaining terms and conditions of the Lease shall remain in
          full force and effect.

          In Witness Whereof, this Lease has been executed on this 25 of
     February, 2004.

     LESSEE:                                 LESSOR:

     COST-U-LESS, INC.                       TONKO REYES, INC.

By:  /s/ J. Jeffrey Meder                By: /s/ Richard J. Untalan
     --------------------------              ------------------------------
     J. Jeffrey Meder                        Richard J. Untalan
     President                               Vice President/General Manager

<PAGE>

AGANA, GUAM     )ss.

     I certify that I know or have satisfactory evidence that RICHARD J. UNTALAN
is the person who appeared before me, and said person acknowledged that he
signed this instrument, on oath stated that he was authorized to execute the
instrument and acknowledge it as the VICE PRESIDENT & GENERAL MANAGER of Tonko
Reyes, Inc., to be the free and voluntary act of such party (ies) for the uses
and purposes mentioned in the instrument.

     DATED this 26 day of February, 2004.

                                     /s/ Andrew J. Zawalinski
                                     -------------------------------------------
                                     Notary Signature a Notary Public in and for
                                     the U.S. Territory of Guam
                                     My Commission Expires Jan. 11, 2005

<PAGE>

STATE OF       Washington  )
                           )ss.
COUNTRY OF        King     )

     I certify that I know or have satisfactory evidence that J. JEFFREY MEDER
is the person who appeared before me, and said person acknowledged that he
signed this instrument, on oath stated that he was authorized to execute the
instrument and acknowledge it as the PRESIDENT of Cost U Less, Inc., to be the
free and voluntary act of such party (ies) for the uses and purposes mentioned
in the instrument.

     DATED this 25 day of February, 2004.

                                        /s/ Sherry Turner
                                        --------------------------------------
                                        Notary Signature

                                        Sherry Turner
                                        --------------------------------------
                                        Print/Type Name
                                        Notary Public in and for the State of
                                        Washington,
                                        Residing at Bellevue, WA
                                        My Commission Expires 03/09/06

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00063-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00063-of-00352.parquet"}]]