Document:

<PAGE>

                                 EXHIBIT 10.96

                   GUARANTY OF LEASE FOR THE NISSAN PROPERTY
<PAGE>

                               GUARANTY OF LEASE

          THIS GUARANTY OF LEASE ("Guaranty") is made as of this 19/TH/ day of
September, 2001 by NISSAN NORTH AMERICA, INC., a California corporation
("Guarantor"), to and for the benefit of WELLS OPERATING PARTNERSHIP, L.P., a
Delaware limited partnership ("Landlord").

                              W I T N E S S E T H:

          For value received and in order to induce Landlord to execute that
certain lease ("Lease") dated September 19, 2001 by and between Landlord and
Nissan Motor Acceptance Corporation, a California corporation, as tenant
("Tenant"), Guarantor hereby agrees to the following:

          1.  Guarantor unconditionally guarantees the payment when due of all
payment obligations (including, but not limited to, payment of rent) imposed
upon Tenant under the terms of the Lease, when and as the same shall become due
thereunder, and the payment of all costs and expenses incurred by Landlord
arising out of or in connection with Tenant's failure to fulfill non-monetary
obligations imposed upon Tenant under the terms of the Lease..  This Guaranty is
a guaranty of payment (not of collection).

          2.  Guarantor agrees that Landlord shall not be first required to
enforce against Tenant or any other person any obligation guaranteed hereby
before seeking enforcement thereof against Guarantor.  Suit may be brought and
maintained against Guarantor by Landlord to enforce any obligation guaranteed
hereby without joinder of Tenant or any other person.  Guarantor's liability
hereunder shall not be affected by any termination of the Lease.

          3.  This Guaranty shall be enforceable against Guarantor without the
necessity of any suit or proceeding on Landlord's part of any kind or nature
whatsoever against Tenant and without the necessity of any notice of non-
payment, non-performance or non-observance or of any notice of acceptance of
this Guaranty or of any other notice or demand to which Guarantor might
otherwise be entitled other than as provided herein, all of which Guarantor
hereby expressly waives.

          4.  Except for the exercise of the options to extend the term of the
Lease set forth in Paragraph 4 of the Lease, the liability of the Guarantor
under this Guaranty shall not be increased, extended or otherwise adversely
affected by any amendment, modification, waiver or any change in the Lease that
is made without the written consent of the Guarantor and which would have the
effect of increasing or extending the obligations of Tenant or otherwise
changing such obligations in a way that would be adverse to Tenant or the
Guarantor.

          5.  The liability of Guarantor hereunder is absolute and unconditional
and shall in no way be affected by (a) the release or discharge of Tenant in any
creditors, receivership, bankruptcy, or other proceedings; (b) the impairment,
limitation or modification of the liability of Tenant or the estate of Tenant in
bankruptcy or of any remedy for the enforcement of Tenant's liability under the
Lease, resulting from the operation of any present or future provisions of the
United States Bankruptcy Code or other statute or from the decision in any
court; (c) the

<PAGE>

rejection or disaffirmance of the Lease in any such proceedings; (d) the
assignment or transfer of the Lease by Tenant to any subsidiary or affiliate of
Guarantor; (e) any disability or other defense of Tenant other than the defense
of payment and the rights of set off, abatement and credit expressly set forth
in the Lease; (f) the assertion or the failure to assert by Landlord against
Tenant of any of the rights or remedies reserved by Landlord pursuant to the
terms, covenants and conditions of the Lease, or (g) any non-liability of Tenant
under the Lease due to any other defect or defense which may now or hereafter
exist in favor of Tenant except for the rights of set off, abatement and credit
expressly set forth in the Lease. The liability of Guarantor hereunder shall in
no way be affected, modified or diminished by reason of any bankruptcy,
insolvency, reorganization, liquidation, arrangement, assignment for the benefit
of creditors, receivership, trusteeship or similar proceeding affecting Tenant,
whether or not notice thereof is given to Guarantor.

          6.  Until all the covenants and conditions in the Lease on Tenant's
part to be performed and observed are fully performed and observed, Guarantor
(a) shall have no right of subrogation against Tenant by reason of any payments
by Guarantor in compliance with the obligations of Guarantor hereunder; and (b)
waives any right to enforce any remedy which Guarantor now or hereafter shall
have against Tenant by reason of any one or more payments made by Guarantor to
Landlord in compliance with the obligations of Guarantor hereunder.

          7.  This Guaranty shall be binding upon Guarantor and the successors
and assigns of Guarantor, and shall inure to the benefit of Landlord and its
successors and assigns.

          8.  This Guaranty shall be governed by the laws of the State of Texas.

          9.  The Guarantor acknowledges that it will benefit by Tenant entering
into the Lease with Landlord.

          10.  Should Landlord be obligated by any bankruptcy or other law to
repay to Tenant or to Guarantor or to any trustee, receiver or other
representative of either of them, any amounts previously paid, this Guaranty
shall be reinstated in the amount of such repayments.  Landlord shall not be
required to litigate or otherwise dispute its obligations to make such
repayments if it in good faith believes that such obligation exists.

                                                                            2
<PAGE>

          IN WITNESS WHEREOF, Guarantor has executed this instrument in the day
and year first above written.

                                   NISSAN NORTH AMERICA, INC.

                                   By: /s/ James C. Morton, Jr.
                                      --------------------------------------
                                   Name: James C. Morton, Jr.
                                        -------------------------------------
                                   Title: Senior Vice President, Admistration
                                         ------------------------------------
                                            and Finance
                                         ------------------------------------

Address for Notices:

     Nissan North America, Inc.
     Attn: Ted Maslin, Corporate Manager, Real Estate and Facilities
     330 West Victoria Street
     Gardena, California 90248
     FAX: 310-771-6084
     E-Mail: ted.maslin@nissan-usa.com

     with a copy to:

     Nissan North America, Inc.
     Attn: Legal Department
     990 West 190/th/ Street
     Torrance, California 90502
     FAX: 310-515-6750
     E-Mail: sue.derian@nissan-usa.com

                              Federal Identification Number:
                              95-2108010

                            SECRETARY'S CERTIFICATE

     The undersigned hereby certifies that she is the Assistant Secretary of
Guarantor, and as such has knowledge of the facts stated in this Certificate,
that the foregoing Guaranty was executed and delivered by Guarantor pursuant to
due authorization of the Board of Directors of Guarantor, and that the officers
of the corporation who signed the Guaranty on behalf of the corporation were the
then incumbents of the offices set forth under their respective names, and as
such officers were duly authorized to execute said Guaranty on behalf of the
Guarantor.

     DATED this 19/TH/ day of September, 2001.

                              /s/ Susan M. Derian
                              ------------------------------
                              Assistant Secretary

                                                                             3<PAGE>

                                 EXHIBIT 10.97

                 DEVELOPMENT AGREEMENT FOR THE NISSAN PROPERTY
<PAGE>

                              DEVELOPMENT AGREEMENT

                                     BETWEEN

                        WELLS OPERATING PARTNERSHIP, L.P.
                                      Owner

                                       AND

                             CHAMPION PARTNERS, LTD.
                                    Developer

                               September 19, 2001
<PAGE>

                                TABLE OF CONTENTS
                                -----------------
<TABLE>
<CAPTION>
                                                                                                      Page
                                                                                                      ----
<S>                                                                                                   <C>
ARTICLE 1 DEFINITIONS............................................................................        1

ARTICLE 2 ENGAGEMENT OF THE DEVELOPER............................................................        4
        2.1 Engagement...........................................................................        4
        2.2 Relationship.........................................................................        5

ARTICLE 3 TERM OF AGREEMENT......................................................................        5

ARTICLE 4 RESPONSIBILITIES OF THE DEVELOPER......................................................        5
        4.1 General Responsibility...............................................................        5
        4.2 Pre-Development Phase................................................................        6
        4.3 Design Development Phase.............................................................        8
        4.4 Construction Phase...................................................................       10
        4.5 All Phases...........................................................................       15
        4.6 Completion...........................................................................       18
        4.7 Employees............................................................................       18
        4.5 Developer's Costs....................................................................       19

ARTICLE 5 DEVELOPMENT BUDGET.....................................................................       19
        5.1 Implementation of Development Budget.................................................       19
        5.2 Revision of Development Budget.......................................................       20
        5.3 Emergencies..........................................................................       20
        5.4 Reduction in Fees....................................................................       20
        5.5 Developer's Obligation for Overage...................................................       21

ARTICLE 6 AUTHORITY OF THE DEVELOPER.............................................................       22
        6.1 General Authority....................................................................       22
        6.2 Execution of Documents and Agreements................................................       22
        6.3 Ratification of Prior Actions of Developer...........................................       22

ARTICLE 7 ACCOUNTING AND REPORTS.................................................................       22
        7.1 Books of Account.....................................................................       22
        7.2 Monthly Reports......................................................................       23
        7.4 Annual Development and Financial Statements..........................................       24
        7.5 Examination of Books and Records.....................................................       24

ARTICLE 8 BANKING................................................................................       24
        8.1 Separate Accounts....................................................................       24
        8.2 The Owner's Duty to Provide Funds....................................................       24
        8.3 Investment of Owner's Funds..........................................................       25
</TABLE>
<PAGE>

<TABLE>

<S>                                                                                                                     <C>
ARTICLE 9 STANDARD OF CARE; LIABILITY; INDEMNITY; CONFIDENTIALITY................................................       25
        9.1 Standard of Care; Developer's Liability..............................................................       25
        9.2 Indemnity of Owner...................................................................................       25
        9.3 Indemnity of Developer...............................................................................       25
        9.4 Survival of Indemnities..............................................................................       26
        9.5 No Obligation to Third Parties.......................................................................       26
        9.6 Nature of the Developer's Duties and Responsibilities................................................       26
        9.7 Ownership of Information and Materials...............................................................       26

ARTICLE 10 INSURANCE.............................................................................................       27
        10.1 Insurance Requirements..............................................................................       27
        10.3 Waiver of Subrogation...............................................................................       27

ARTICLE 11 COMPENSATION OF THE DEVELOPER.........................................................................       27
        11.1 Fees - General......................................................................................       27
        11.2 Development Fee.....................................................................................       27
        11.5 Leasing Fee.........................................................................................       28
        11.4 Nissan Work Fee.....................................................................................       28
        11.5 Reimbursement of Costs..............................................................................       29
        11.6 Disbursements to the Developer......................................................................       29

ARTICLE 12 RENT CREDITS, REIMBURSEMENTS..........................................................................       29
        12.1 Payment by Developer of Rent Credits................................................................       29
        12.2 Reimbursement by Owner of Advances..................................................................       29
        12.3 Reimbursement by Owner of Costs and Expenses........................................................       29

ARTICLE 13 DEFAULT AND TERMINATION...............................................................................       30
        13.1 Default by Developer................................................................................       30
        13.2 Additional Terminating Event........................................................................       31
        13.3 Default by Owner....................................................................................       31
        13.4 Obligation for Fees Upon Termination................................................................       31
        13.5 Actions Upon Termination............................................................................       31
        13.6 Interest............................................................................................       32

ARTICLE 14 OTHER ACTIVITIES OF THE DEVELOPER.....................................................................       32

ARTICLE 15 NATURE OF AGREEMENT...................................................................................       32

ARTICLE 16 GENERAL PROVISIONS....................................................................................       32
        16.1 Notices.............................................................................................       32
        16.2 Modifications.......................................................................................       33
        16.3 Binding Effect......................................................................................       33
        16.4 Duplicate Originals.................................................................................       33
        16.5 Construction........................................................................................       34
        16.6 Entire Agreement....................................................................................       34
        16.7 Assignment..........................................................................................       34
        16.8 Authorized Representatives..........................................................................       34
</TABLE>

                                      ii
<PAGE>

<TABLE>
<S>                                                                                                   <C>
     16.9  Terminology...........................................................................      35
     16.10 Time of Essence.......................................................................      35
</TABLE>

Exhibits:
--------

Exhibit "A"       Description or Site Plan of Fee Parcel Comprising Land
Exhibit "B"       Development Budget
Exhibit "C"       Insurance Requirements
Exhibit "D"       Reimbursable Expenditures Relating to Project
Exhibit "E"       Form of Estoppel Certificate
Exhibit "F"       Total Project Cost Defined
Exhibit "G"       Lien Waiver and Claim Waiver Forms
Exhibit "H"       Actions of Developer Ratified by Owner
Exhibit "I"       Nissan Lease Takeover and Land Purchase

                                      iii
<PAGE>

                             DEVELOPMENT AGREEMENT
                             ---------------------

     THIS AGREEMENT, made and entered into this 19 day of September, 2001, by
and between WELLS OPERATING PARTNERSHIP, L.P., a Delaware limited partnership
(hereinafter referred to as the "Owner"), and CHAMPION PARTNERS, LTD., a Texas
limited partnership (hereinafter referred to as the "Developer").

                             W I T N E S S E T H:
                              - - - - - - - - - -

     WHEREAS, the Owner owns or has the contractual right to acquire a certain
parcel of land located in the Freeport Business Park in the City of Irving,
Dallas County, Texas, on which the Owner proposes to develop and construct an
office building with related parking, landscaping and other site work pursuant
to plans and specifications prepared and to be prepared by HKS, Inc.; and

     WHEREAS, the Owner desires to engage the Developer as an independent
contractor, upon the terms and conditions set forth herein, to supervise and to
manage the development and construction of such building and other improvements
and to lease space in such building to Nissan; and

     WHEREAS, the Developer desires to perform such services for the Owner in
consideration of the compensation set forth herein.

     NOW, THEREFORE, for and in consideration of the premises, the sum of Ten
Dollars ($10.00) in hand paid by each party to the other, and the mutual
promises, obligations and agreements contained herein, the Owner and the
Developer, intending to be, and being, legally bound, do hereby agree as
follows:

                                   ARTICLE 1
                                   ---------
                                  DEFINITIONS
                                  -----------

     For purposes of this Agreement, each of the following terms shall, when
used herein with an initial capital letter, have the meaning hereinbelow set
forth.

     Agreement.  The term "Agreement" means this Development Agreement, together
     ---------
with all amendments hereto and all exhibits attached hereto.

     Architect.  The term "Architect" means the architectural firm of HKS, Inc.
     ---------
and any other firm employed by the Owner as an architect with respect to the
Project.

     Architect's Agreement.  The term "Architect's Agreement" means the
     ---------------------
agreement(s) between the Owner and the Architect under which the Architect has
been or shall be engaged to prepare architectural designs, plans, drawings and
specifications for the Project and to render
<PAGE>

other services in connection with the design and construction of the Project.
The Architect's Agreement is incorporated herein by this reference.

     Building.  The term "Building" means a first-class, single tenant, three-
     --------
story office building, containing approximately 268,290 gross square feet, which
the Owner intends to develop and construct upon the Land.

     Capitalized Rent Amount.  The term "Capitalized Rent Amount" is defined in
     -----------------------
Section 5.4 hereof.

     CC&R.  The term "CC&R" is defined in Section 4.5.10 hereof.
     ----

     Communication System Plan.  The term "Communication System Plan" is defined
     -------------------------
in Section 4.5.4 hereof.

     Completion Date.  The term "Completion Date" means the first day on which
     ---------------
all of the following have occurred:  (i) the construction and equipping of the
Project has been substantially completed in accordance with Architect's plans
and specifications (inclusive of landscaping plans, to the extent that
landscaping can feasibly be installed due to the season), as evidenced by a
certificate to such effect from the Architect, (ii) appropriate certificates of
occupancy or their equivalent have been issued by the appropriate governmental
authority with respect to the core and shell portion of the Building and with
respect to the space in the Building to be occupied by Nissan, (iii) the Rent
Commencement Date under the Nissan Lease has occurred and either Nissan is
actually paying Base Rent under the Nissan Lease or Base Rent is then due and
payable but Nissan is effectuating a credit against Base Rent under Paragraphs 2
or 7 of Exhibit "C" attached to the Nissan Lease or under Exhibit "D" attached
to the Nissan Lease, and (iv) Nissan has executed and delivered to the
"Landlord" under the Nissan Lease an estoppel certificate substantially in the
form attached hereto as Exhibit "E" and by reference made a part hereof.
                        -----------

     Construction Agreement.  The term "Construction Agreement" means,
     ----------------------
collectively, the construction contract between the Owner and the Contractor
with respect to the Project and such other construction or employment agreements
as may be hereafter entered into by the Owner and a general contractor or
special purpose contractor with respect to the performance of work or the
providing of services to the Project.  The Construction Agreement is
incorporated herein by this reference.

     Construction Documents.  The term "Construction Documents" means,
     ----------------------
collectively, the Architect's plans and specifications for the Project, the
Construction Agreement, the Architect's Agreement, and the agreements between
Owner and the other Owner Consultants.

     Contractor.  The term "Contractor" means, collectively, Thos. S. Byrne Inc.
     ----------
and all other firms employed by the Owner as a general contractor or as a
special purpose contractor with respect to the Project; and singly any such
general or special purpose contractor.

     Contractor CPM Schedule.  The term "Contractor CPM Schedule" is defined in
     -----------------------
Section 4.4.11 hereof.

                                      -2-
<PAGE>

     Developer.  The term "Developer" means Champion Partners, Ltd., a Texas
     ---------
limited partnership.

     Development Budget.  The term "Development Budget" means the budget, a copy
     ------------------
of which is attached hereto and made a part hereof as Exhibit "B", which sets
                                                      -----------
forth the Developer's best estimate of all expenses to be incurred with respect
to the acquisition of the Land, the planning, design, development, construction
and completion of the Project, including the Tenant Improvements for Nissan.

     Development Fee.  The term "Development Fee" means the fee to be paid to
     ---------------
the Developer by the Owner as provided in Section 11.2 hereof.

     Development Functions.  The term "Development Functions" means those
     ---------------------
functions of the Developer set forth in Section 4.2 of this Agreement.

     Development Period.  The term "Development Period" means the period
     ------------------
commencing on the date of this Agreement and terminating on the date which is
three (3) months after the Completion Date.

     Event of Default.  The term "Event of Default" means any one or more of the
     ----------------
events described in Section 13.1 of this Agreement.

     Land.  The term "Land" means that certain parcel of land containing
     ----
approximately 14.873 acres located in the Freeport Business Park in the City of
Irving, Dallas County, Texas, as more particularly shown or described on Exhibit
                                                                         -------
"A" attached hereto and by this reference made a part hereof.
---

     Leasing Fee.  The term "Leasing Fee" means the fee to be paid to the
     -----------
Developer by the Owner as provided in Section 11.3 hereof.

     Memorandum.  The term "Memorandum" is defined in Exhibit "I" attached
     ----------                                       -----------
hereto and by reference made a part hereof.

     Monthly Report.  The term "Monthly Report" means the report to be prepared
     --------------
by the Developer and submitted to the Owner on a monthly basis as provided in
Section 7.2 hereof.

     Nissan.  The term "Nissan" means Nissan Motor Acceptance Corporation, a
     ------
California corporation.

     Nissan Lease.  The term "Nissan Lease" means the Lease Agreement between
     ------------
Owner and Nissan dated September __, 2001.

     Owner.  The term "Owner" means Wells Operating Partnership, L.P., a
     -----
Delaware limited partnership.

                                      -3-
<PAGE>

     Owner Consultant.  The term "Owner Consultant" is defined in Section 4.2.3
     ----------------
hereof.

     Project.  The term "Project" means the Land, the Building, the Site
     -------
Improvements, and the Tenant Improvements, collectively.

     Project Requirements.  The term "Project Requirements" is defined in
     --------------------
Section 4.2.4 hereof.

     Project Schedule.  The term "Project Schedule" is defined in Section 4.2.5
     ----------------
hereof.

     QAC Plan.  The term "QAC Plan" is defined in Section 4.4.6 hereof.
     --------

     Rent Commencement Date.  The term "Rent Commencement Date" means the "Rent
     ----------------------
Commencement Date" under the Nissan Lease, which is the date that full Base Rent
shall commence to be due and payable under the Nissan Lease.

     Reserve Account.  The term "Reserve Account" is defined in Exhibit "I"
     ---------------                                            -----------
attached hereto.

     Safety Plan.  The term "Safety Plan" is defined in Section 4.4.8 hereof.
     -----------

     Site Improvements.  The term "Site Improvements" means the surface level
     -----------------
parking facilities, sufficient to accommodate approximately 1,056 automobiles
on-site, any and all on and off-site road improvements, walkways, complete
utilities and drainage systems, landscaping work, exterior lighting, ground-
mounted signs and other site improvements which the Owner intends to develop and
construct upon the Land.

     Tenant Improvements.  The term "Tenant Improvements" means the tenant
     -------------------
improvements required to be installed or constructed by the "Landlord" under the
Nissan Lease.

     Tenant Occupancy Fee.  The term "Tenant Occupancy Fee" means the fee to be
     --------------------
paid to the Developer by the Owner as provided in Section 11.4 hereof.

     Total Lease Takeover Net Costs.  The term "Total Lease Takeover Net Costs"
     ------------------------------
is defined in Exhibit "I" attached hereto.
              -----------

     Total Project Costs.  The term "Total Project Costs" is defined in Exhibit
     -------------------                                                -------
"F" attached hereto and by reference made a part hereof.
---

                                   ARTICLE 2
                                   ---------
                          ENGAGEMENT OF THE DEVELOPER
                          ---------------------------

     2.1  Engagement.  The Owner hereby engages the Developer as the exclusive
          ----------
development manager of the Project to supervise, to manage, and to coordinate
the planning, design, construction, and completion of the Project, all in
accordance with the terms, conditions and limitations herein set forth.  The
Developer hereby accepts such engagement and hereby

                                      -4-
<PAGE>

agrees to diligently use commercially reasonable efforts in the performance of
its duties and the Development Functions hereunder, which performance in all
respects and at all times shall be carried out to the same extent and with the
same degree of care and quality as the Developer would exercise in the conduct
of its own affairs if the Developer were the owner of the Project. The Developer
agrees to apply prudent and reasonable business practices in the performance of
its duties hereunder and shall exercise that degree of skill, competence,
quality and professional care rendered by the leading and most reputable
companies performing the same or similar type services for first-class quality
office projects in the metropolitan Dallas, Texas, area. The Developer will not
subcontract any of its services to any other entity or person without first
obtaining Owner's prior written consent.

     2.2  Relationship.  With respect to the Owner, the Developer shall at all
          ------------
times be an independent contractor.  No provision hereof shall be construed to
constitute the Developer or any of its officers or employees as an employee or
employees of the Owner nor shall any provision of this Agreement be construed as
creating a partnership or joint venture between the Developer and the Owner.
Neither the Owner nor the Developer shall have the power to bind the other party
except pursuant to the terms of this Agreement.  Developer agrees to conform its
general policies and procedures to any commercially reasonable requirements of
any lender providing construction financing for the acquisition and construction
of the Project.  In addition, if Owner disapproves of any of the general
policies and procedures of the Developer with respect to the Project and shall
have so notified the Developer, the Developer shall conform its general policies
and procedures with respect to the Project to those requested by the Owner
insofar as such policies may be consistent with the terms and provisions of this
Agreement and do not create additional expense to the Developer.

                                   ARTICLE 3
                                   ---------
                               TERM OF AGREEMENT
                               -----------------

     The engagement of the Developer hereunder shall commence on the date on
which this Agreement is executed and shall end on the date which is three (3)
months from and after the Completion Date (except for the terms of Exhibit "I"
                                                                   -----------
attached hereto, which shall end on the date which is eighteen (18) months from
and after the Completion Date); provided, however, if any remedial work to be
performed by the Contractor following the completion of the Project has not been
completed, the term of this Agreement shall be extended until the date on which
any remedial work required to be performed by the Contractor following
completion of the Project shall be so performed and accepted by the Owner.

                                   ARTICLE 4
                                   ---------
                       RESPONSIBILITIES OF THE DEVELOPER
                       ---------------------------------

     4.1  General Responsibility.  The Developer's general responsibility
          ----------------------
hereunder as the Owner's development manager shall be to manage, supervise, and
coordinate the planning, design, construction, and completion of the Project.
Such general responsibility of Developer,

                                      -5-
<PAGE>

together with the other responsibilities of Developer set forth in Sections 4.2
through 4.5 below, are herein collectively referred to as the "Development
Functions".

     4.2  Pre-Development Phase.  During the Pre-Development Phase of the
          ---------------------
Project (which shall include, but not be limited to, the Pre-Design, Pre-
Construction, Negotiation and Schematic Design Phases of the Architect's
services), Developer's responsibilities shall include the following:

          4.2.1  The Developer has prepared the Development Budget.

     4.2.2 The Developer and Owner shall negotiate the Architect's Agreement,
     and such Architect's Agreement either will be executed by Developer as
     "Owner" thereunder and then assigned by Developer to Owner or will be
     submitted to Owner for execution by Owner. Owner may elect to thereafter
     assign the Architect's Agreement to the Contractor.

          4.2.3  The Developer shall recommend to Owner engineering, interior
     design and other specialists and consultants for the Project, shall
     coordinate the process for the selection and/or approval by Owner of such
     specialists and consultants for the Project, shall review and analyze
     proposals from such specialists and consultants, and, following written
     approval thereof by Owner, shall negotiate (on terms consistent with and
     within limitations of the Development Budget), review and evaluate proposed
     contracts between Owner and such specialists and consultants or between
     Architect and such specialists and consultants (it being the current
     intention of Owner that Architect will engage directly the MEP engineer,
     structural engineer, landscape architect, and civil engineer). The
     contracts with such specialists and consultants (other than those engaged
     directly by the Architect) either will be entered into by Developer as
     "Owner" thereunder and then assigned by Developer to Owner or will be
     submitted to Owner for execution by Owner. Once Owner has accepted an
     assignment of a contract with a specialist or consultant or entered into a
     contract with a specialist or consultant, such specialist or consultant
     (including the Architect) shall be referred to as an "Owner Consultant".

          4.2.4  The Developer shall assist Owner in establishing and developing
     the Project's design criteria and Project requirements and, upon approval
     by Owner in writing, such approved criteria shall form the basis upon which
     the design of the Project shall be measured. Such approved design criteria
     and Project requirements shall be referred to as the "Project
     Requirements".

          4.2.5  The Developer shall establish and develop a critical-path-
     method schedule for the Project for Owner's written approval. Once approved
     by Owner, such schedule shall be referred to as the "Project Schedule". The
     Project Schedule shall show the start and finish dates and schedule for the
     planning, design, materials and equipment procurement and the construction
     of the Project, and shall show all critical milestone dates. The Project
     Schedule shall be consistent with the dates for substantial completion and
     final completion of the Project contained in the Nissan Lease. Subject to
     the notice and cure provisions under Section 13.1 of this Agreement,
     failure of Developer to comply

                                      -6-
<PAGE>

     in all material respects with its scheduling obligations set forth in this
     Agreement may be deemed to be a default under this Agreement entitling
     Owner to terminate Developer for cause under Section 13.1 hereof, unless
     such failure is due to force majeure. No delay in the planning,
     construction or completion of the Project or of the Rent Commencement Date
     under the Nissan Lease which is caused by force majeure shall affect or
     reduce the calculation of Total Project Costs.

          4.2.6  The Developer shall initiate and monitor the preparation by
     Owner Consultants of boundary and topographic surveys of the Land or
     applicable portions thereof.

          4.2.7  The Developer shall initiate and monitor the preparation by
     Owner Consultants of site plans showing the location of roads, utilities,
     buildings, parking areas and other improvements to be constructed in
     connection with the Project.

          4.2.8  The Developer shall initiate and monitor the preparation by
     Owner Consultants of preliminary drawings, specifications and other
     documents (including, but not limited to, the preliminary drawings,
     specifications and other documents produced by the Architect or its
     consultants during the Pre-Design Phase or Schematic Design Document Phase)
     in accordance with the approved Project Requirements.

          4.2.9  If requested by Owner, the Developer shall arrange for and
     identify potential specialists and consultants to prepare environmental
     Phase I reports with respect to the Land, and Developer shall consult with
     Owner and the selected Owner Consultants as to such other environmental
     reports as may be deemed necessary or desirable to ascertain what, if any,
     environmental risks or liabilities may exist with respect to the Land.

          4.2.10 The Developer shall arrange for and identify potential
     specialists and consultants for Owner's written approval to perform soil
     testing on the Land and upon which the foundations and substructure of the
     Project will be located to determine if the soil is suitable for the
     construction of the Project and to determine the likelihood of excessive
     expenses which may be required for excavation and soil work on the Project.

          4.2.11 The Developer shall initiate and monitor the preparation of
     geotechnical, architectural, engineering and other studies necessary for
     the development of the Project with the Architect and other Owner
     Consultants.

          4.2.12 Developer shall advise Owner with respect to any traffic
     planning issues, historic preservation issues, and aesthetic issues.

          4.2.13 The Developer shall coordinate the acquisition by the Owner of
     the Land.

          4.2.14 The Developer shall provide cost evaluations of alternatives
     to the Project Requirements, including, without limitation, use of
     materials, equipment, systems, and

                                      -7-
<PAGE>

     construction methods that could result in lower costs due to greater energy
     efficiency, longer life, lower maintenance and ease of operation.

     4.3  Design Development Phase.  During the Design Development Phase of the
          ------------------------
Project, which shall include, but not be limited to, the Design Development and
Construction Document phases of the Architect's services, Developer shall
coordinate with Owner and with the Contractor, the Architect and the other Owner
Consultants to obtain Design Development Documents (including appropriate
materials, mock-ups, color samples and sample interior finish boards) acceptable
to Owner and Nissan, and Developer's responsibilities will include the
following:

          4.3.1  The Developer shall review design drawings and specifications,
     including, without limitation, design development documents and
     construction documents prepared by Architect and its consultants, shall
     make recommendations to the Owner and Architect regarding their
     constructability, expected cost, and schedule, and shall coordinate any
     changes in such design drawings and specifications requested by Owner. The
     Developer shall promptly give the Architect and Owner written notice of any
     issues concerning constructability, expected cost or schedule that may have
     an adverse impact on the Project; provided, however, Developer's actions
     with respect to the design shall be advisory to the Owner and Architect and
     shall not constitute an undertaking on the part of the Developer for the
     adequacy or constructability of the design, and Owner and Developer agree
     that the responsibility for the design rests with the Architect. In
     addition, the Developer shall during its reviews provide recommendations on
     the selection of materials, building systems and equipment, methods of
     Project delivery, relative feasibility of construction methods and the
     preferred construction method, availability of materials and labor, time
     requirements for procurement, installation and construction, and factors
     related to construction cost including, but not limited to, costs of
     alternative designs or materials, the Development Budget, and possible
     economies. The Developer's review and comments on the design shall be
     advisory to the Owner and Architect and shall not constitute an undertaking
     on the part of the Developer for the adequacy or constructability of the
     design. Owner and Developer agree that the responsibility for the design
     rests with the Architect.

          4.3.2  The Developer shall work with the Architect and the other Owner
     Consultants to achieve compatibility and coordination of all design
     drawings and specifications (including, but not limited to, design
     development documents and construction documents prepared by Architect and
     its consultants and any other documents prepared by any other Owner
     Consultants) with each other. The Developer's review and comments with
     respect to such design drawings and specifications shall be advisory to the
     Owner and Architect, and Developer shall have no liability to Owner if any
     such design drawings and specifications are not compatible with each other
     unless, however, Developer has actual knowledge of such incompatibility and
     fails to give Owner and Architect timely notice of such incompatibility.

          4.3.3  The Developer shall arrange to be prepared a description of
     standard interior finishes for the interior of the base building
     improvements comprising the Project

                                      -8-
<PAGE>

     (excluding any Tenant Improvements), together with a budget for the
     installation of such finishes.

          4.3.4  The Developer shall obtain and review the cost estimates from
     Owner Consultants and/or potential contractors for the Project and the
     preparation of estimates of the projected Project cost in light of design
     development, and providing a comparison with the established Development
     Budget.

          4.3.5  The Developer shall review and evaluate claims by Owner
     Consultants and, if necessary, conduct an investigation. Developer shall
     forward claims to the Owner along with its recommendations. For claims
     approved by Owner, Developer shall process change orders as provided in
     this Agreement and the relevant agreement between the Owner and the
     affected party.

          4.3.6  The Developer shall review and approve critical-path-method
     schedules for each of the Owner Consultants for compliance with the Project
     Schedule and milestones and coordination with other entities and persons
     performing services or work on the Project.

          4.3.7  The Developer shall provide to Owner updates to the Project
     Schedule and progress reports as required under Sections 4.5.6 and 7.2
     below.

          4.3.8  Developer shall review and evaluate the invoices from Owner
     Consultants against actual progress to determine whether the amount claimed
     as the percent complete is accurate. Developer shall certify the amounts
     due Owner Consultants. Developer may certify, modify or withhold
     certification for payment, and shall require necessary revisions in such
     invoices. Developer will submit certified Project invoices to the Owner for
     review and approval along with a report summarizing the status of payments
     to Owner Consultants and the cost of the Project. The Developer's
     certification for payment shall constitute a representation to the Owner,
     based on the Developer's determinations and on the data comprising the
     Owner Consultant invoices, that, to the best of the Developer's knowledge,
     information and belief, the services have progressed to the point
     indicated, except as stated in the certification for payment.

          4.3.9  The Developer shall perform and provide the services with
     respect to change orders, change order requests and change order proposals
     relating to agreements between Owner and Owner Consultants as set forth in
     Section 4.4.9 hereof.

          4.3.10 The Developer shall coordinate the finalization of the
     construction documents for the Project, including but not limited to,
     drawings and specifications for architectural, structural, civil,
     mechanical, electrical, plumbing, acoustical, lighting, fire protection,
     life safety, landscaping, and interior design.

          4.3.11 The Developer shall identify and recommend to Owner proposed
     Contractors and major subcontractors for the Project, shall coordinate the
     process for the selection by Owner of the Contractor and major
     subcontractors, and shall analyze

                                      -9-
<PAGE>

proposals from and make recommendations with respect to such proposed
                    Contractors and major subcontractors.

          4.3.12  The Developer and Owner shall negotiate the Construction
     Agreement, and such Construction Agreement either will be executed by
     Developer as "Owner" thereunder and then assigned by Developer to Owner or
     will be submitted to Owner for execution by Owner. The Construction
     Agreement shall require the Contractor to furnish payment and performance
     bonds for work on the Project, unless such requirement is otherwise waived
     in writing by Owner.

          4.3.13  The Developer shall administer and oversee the selection by
     the Contractor of major subcontractors and others as appropriate for
     construction of any improvements Owner authorizes to be constructed on the
     Project and shall review for acceptability the bids received from major
     subcontractors.

          4.3.14  The Developer shall obtain or cause the Contractor to obtain
     building, development, and other permits necessary to commence and complete
     construction of the Project. The Developer shall coordinate the submission
     of the applicable construction documents to governmental authorities for
     review and approval. The Developer shall coordinate revision and
     resubmission of such documents where required by governmental authorities.

          4.3.15  The Developer shall work with Owner and the Contractor, the
     Architect and other Owner Consultants to identify long lead-time materials
     and equipment requested by Owner as to the Project or otherwise included in
     the Construction Documents approved by Owner, and Developer shall advise
     Owner as to making appropriate arrangements for the procurement of same.

     4.4  Construction Phase.  Once construction of the Project commences,
          ------------------
Developer's responsibilities will include the following:

          4.4.1   The Developer shall manage the Project as the Owner's
     representative. Developer shall coordinate and manage the activities of the
     Project, including the activities of the Developer, Architect, Owner
     Consultants and Contractor in order to meet the Project milestones, the
     Project Schedule and the Development Budget and consistent with the
     Communication System Plan, the Project Requirements and the Construction
     Documents.

          4.4.2   The Developer shall conduct pre-construction meetings with the
     Contractor to review the Project Schedule, coordination procedures, the
     Communication System Plan, the QAC Plan, the Safety Plan and other relevant
     information needed to perform at the Project site. Developer shall
     coordinate the production by the Architect or others of meeting minutes of
     each pre-construction meeting and distribute the minutes to participants.

                                     -10-
<PAGE>

          4.4.3  The Developer shall verify that all pre-construction
     submittals, including, without limitation, permits, bonds, insurance
     certificates and notice of commencement, have been made and submitted by
     Contractor prior to performing Work.

          4.4.4  The Developer shall implement the Communication System Plan and
     coordinate compliance by Contractor with the Communication System Plan.

          4.4.5  The Developer shall review all Contractor submittals, requests
     for information and other communications relating to the design or
     Construction Documents for the effect on cost, schedule and Project
     coordination. The Developer shall forward such documents along with
     Developer's comments regarding any detrimental impact that any such
     documents or information contained in such documents may have on the
     Project, to the Architect and Owner for review and approval or other action
     as appropriate. Developer shall forward the Architect's responses to the
     Contractor and the Owner. Developer's review of Contractor submittals shall
     be for conformance with the Contract Documents and shall not relieve
     Contractor of any of its obligations under the Construction Contract.

          4.4.6  The Developer shall review and comment on the Contractor's
     program for quality assurance and control ("QAC Plan") to apply to
     construction and installation of the work, the purpose of which shall be to
     assure that the work is of sufficent quality and in proper conformance with
     the Contract Documents. It shall be the responsibility of the Developer, in
     conjunction with the Architect, to (a) observe during Project visits,
     whether the Contractor and its subcontractors are meeting and complying
     with the requirements of the QAC Plan and (b) promptly report to the Owner
     any failure of any person or entity to adhere to or meet the requirements
     of the QAC Plan of which the Developer has actual knowledge. After
     defective work has been corrected by the Contractor, the Developer shall
     observe the corrected work and determine whether in Developer's reasonable
     judgment the corrected work is in proper conformance with the Construction
     Documents.

          4.4.7  The Developer shall make visits to the Project site to inspect
     the work and progress of construction with the Contractor and with the
     Architect and other Owner Consultants, which visits shall be of such
     frequency and duration as shall be necessary for Developer to carry out its
     duties under this Agreement, to guard against defects and deficiencies in
     the work and to determine that the work is being performed in accordance
     with the Construction Documents, but in no event shall such visits be less
     than four (4) days per week during the Construction Phase. If Developer
     notices such defects or deficiencies in the work or discrepancies between
     the work and the Construction Documents, Developer shall prepare and submit
     to Owner a report within two (2) days of such visit detailing its
     observations. Otherwise, Developer shall prepare and submit to Owner a
     progress report at least every two (2) weeks detailing its observations.
     Developer shall have the authority to require additional inspection or
     testing of the work in accordance with the provisions of the Construction
     Documents at any stage of the Project.

                                     -11-
<PAGE>

          4.4.8   The Developer shall review and comment on the Contractor's
     program for assuring job site safety (the "Safety Plan"). Developer may
     order the Contractor and its subcontractors, suppliers and employees to
     stop work that is not in compliance with the Safety Plan or that is being
     conducted in an unsafe manner. By reviewing and commenting on the Safety
     Plan, including without limitation stopping work that is not in compliance
     with the Safety Plan or that is being conducted in an unsafe manner,
     Developer does not assume any responsibility for Project site safety or the
     taking of safety precautions at the site of any of the work. These
     responsibilities shall remain solely with the Contractor.

          4.4.9   The Developer shall consult with Owner regarding proposed
     changes and modifications to the Construction Documents, and the Developer
     shall coordinate issuance of change orders if and when changes are approved
     in writing by Owner and the affected party. The Developer shall ensure that
     all changes in the work or services are implemented through written change
     orders signed by the Owner and the affected party. The Developer shall
     establish a changes system to control the writing of change orders and to
     record all changes to the Construction Documents. For changes initiated by
     the Owner or Developer with respect to the Contractor's work or
     Construction Agreement, the Developer shall prepare written change order
     proposal requests, incorporating detailed drawings and specifications
     prepared or approved by the Architect where appropriate. The Developer
     shall forward the requests to the Contractor for preparation of a proposal.
     For change order requests initiated by Contractor, the Developer shall
     evaluate the requests and, if applicable, provide a copy to the Architect
     for comment. The Developer shall evaluate change order proposal requests
     for price, schedule and coordination impact and shall forward its
     recommendations to the Owner, along with the comments of the Architect. For
     Owner-approved change order requests, the Developer shall prepare change
     order proposal requests, incorporate detailed drawings and specifications
     prepared or approved by the Architect where appropriate. The Developer
     shall evaluate change order proposals for price, schedule and coordination
     impact and, if applicable, shall provide copies to the Architect for
     comment. The Developer shall forward its recommendations to the Owner along
     with any comments of the Architect. For change order proposals approved by
     the Owner and the affected party, the Developer shall prepare written
     change orders and shall obtain the signatures of the Owner and the affected
     party. If a change is performed by the Contractor or an Owner Consultant
     under a pricing arrangement other than lump sum, Developer shall make a
     record of units, work or services or actual costs incurred as the case may
     be. The Developer shall obtain from the Contractor and Owner Consultants
     copies of supporting documents for all units of work or services or costs
     incurred. The Developer shall keep a record copy of all signed change
     orders and shall provide copies to the Architect and Owner.

          4.4.10  The Developer shall review and evaluate claims by Contractor,
     Architect or other Owner Consultants and, if necessary, conduct an
     investigation of actual conditions. Developer shall provide copies of
     Contractor claims to the Architect for comment. Developer shall forward
     claims to the Owner along with its recommendations, and for Contractor
     claims, comments from the Architect. For claims approved by Owner,

                                     -12-
<PAGE>

     Developer shall process change orders as provided in this Agreement and the
     relevant agreement between the Owner and the affected party.

          4.4.11  The Developer shall review and approve critical-path-method
     schedules of the Contractor ("Contractor CPM Schedule") for compliance with
     the Project Schedule and milestones and coordination with other entities
     and persons performing services or work on the Project.

          4.4.12  The Developer shall receive Contractor's monthly progress
     reports and evaluate the reports against the Contractor CPM Schedule,
     actual conditions, and the Project Schedule. The Developer shall determine
     the actual percent complete of work and shall communicate this percent to
     the Owner, Contractor and Architect. The Developer may require revisions to
     the Contractor progress reports and to the Contractor CPM Schedule, to the
     extent allowed under the Construction Contract; provided, however,
     Developer shall not have the authority to revise the dates required for
     substantial completion and final completion of the Project under the Nissan
     Lease or any other critical milestone.

          4.4.13  The Developer shall provide to Owner updates to the Project
     Schedule and a progress report as required under Sections 4.5.6 and 7.2
     hereof.

          4.4.14  The Developer shall review the Contractor's proposed breakdown
     of the contract values into a schedule of values, which shall be the basis
     of determining the percent complete for progress payments to the
     Contractor. Developer shall modify, accept or reject the schedule of
     values.

          4.4.15  Developer shall review and evaluate all invoices and payment
     applications against actual progress to determine whether the amount
     claimed as the percent complete is accurate. Developer shall certify the
     amounts due Contractor and Owner Consultants. Developer may certify, modify
     or withhold certification for payment, and shall require necessary
     revisions to such invoices. Developer will submit certified Project
     invoices to the Owner for review and approval along with a report
     summarizing the status of payments to Contractor and the construction cost
     of the Project. The Developer's certification for payment shall constitute
     a representation to the Owner, based on the Developer's determinations at
     the site and on the data comprising the Contractor's invoices, that, to the
     best of the Developer's knowledge, information and belief, the work has
     progressed to the point indicated and, except as stated in the
     certification for payment, the quality of the work is in accordance with
     the Construction Documents.

          4.4.16  The Developer shall respond to any questions from Owner
     regarding the work or progress of construction, construction methods,
     scheduling and the like.

          4.4.17  The Developer shall coordinate efforts by all appropriate
     parties to complete the Project in accordance with the Construction
     Documents, as the same may be amended from time to time with the approval
     of all necessary parties, such efforts to

                                     -13-
<PAGE>

     include, without limitation, assisting in the scheduling of inspections and
     the preparation of and overseeing the completion of the Punchlist.

          4.4.18  The Developer shall review the Contractor's notice of
     substantial completion, the Punchlist initially prepared by the Contractor
     and the Punchlist as revised by the Architect. Together with the Owner and
     Architect, Developer shall inspect the work. Developer's inspection will be
     to determine whether substantial completion has been achieved and to verify
     the accuracy and completeness of the Punchlist. Developer shall refuse to
     accept the work as substantially complete if Developer, Owner and Architect
     determine that the work has not been substantially completed. If Owner,
     Developer and Architect agree that the work is substantially complete,
     Developer will coordinate the preparation by the Architect of a certificate
     of substantial completion which shall establish the date of substantial
     completion of the work and shall fix the time within which Contractor shall
     complete the items on the Punchlist. The Developer shall use reasonable
     efforts to obtain the Contractor's written acceptance of the
     responsibilities assigned to Contractor in such certificate.

          4.4.19  The Developer shall assist the Architect or Contractor with
     obtaining, on behalf of Owner, a temporary or final certificate of
     occupancy (or other appropriate and necessary governmental permission to
     occupy) with respect to the Project.

          4.4.20  The Developer shall review the Contractor's final invoices,
     final waiver and release of lien and claim forms and supporting data.
     Developer, together with Owner and Contractor, will inspect the work.
     Developer shall advise the Owner on the acceptability and completeness of
     the work. If Owner accepts the work as complete, the Developer shall
     coordinate the issuance by the Architect of a certificate of final
     completion. Developer shall obtain all documentation required of Contractor
     under the Construction Agreement prior to certifying a final invoice for
     payment. Developer shall forward certified final invoices to Owner for
     payment.

          4.4.21  Developer shall obtain as-built drawings and specifications
     from the Architect and/or Contractor and assemble them into a record set
     for the Project, and forward them to the Architect so that it will record
     all such changes reflected in the as-built drawings and specifications into
     the computer aided design format. Developer shall also obtain record copies
     of all change orders, requests for information, invoices and other
     documents that define the work and the final cost of the work. Developer
     shall obtain from the Contractor and deliver to Owner all operation and
     maintenance manuals, warranties and guarantees.

          4.4.22  Developer shall coordinate the turnover of portions of the
     Project as and when the same are appropriately completed.

          4.4.23  After the Project is completed, the Developer shall prepare a
     final report to the Owner on the construction cost.

                                     -14-
<PAGE>

     4.5  All Phases.  During all phases of the Project, Developer's
          ----------
responsibilities will include the following:

          4.5.1  The Developer shall implement the Development Budget as
     provided herein.

          4.5.2  Developer shall maintain or cause to be maintained true and
     complete Project files at the Dallas, Texas office of Developer, including,
     but not limited to, correspondence, contracts, purchase orders, bids,
     proposals, draw requests and Monthly Reports. Developer shall also maintain
     or cause to be maintained all data and information pertaining to the
     Development Functions and reimbursable costs. Such records and files shall
     be provided to Owner upon Owner's request and shall be maintained in
     accordance with Developer's present method of accounting, unless otherwise
     directed or approved by Owner. Developer may also maintain other records or
     books for Owner and which are owned by Owner and to which Owner has
     complete access.

          4.5.3  Developer shall schedule and conduct periodic meetings
     throughout the course of the Project to review the design, procurement and
     construction as to progress, quality and compliance with the Project
     Requirements, Project Schedule, Development Budget, and, during the
     Construction Phase, for compliance with the Construction Documents. Such
     meetings shall occur at least every week during the Pre-Development and
     Design Development Phases and at least bi-weekly during the Construction
     Phase, unless Owner requests more frequent meetings. The Developer shall
     arrange for the attendance of all necessary parties at the periodic
     meetings, including without limitation, the Owner, Architect, other Owner
     Consultants, Contractor, subcontractors, key suppliers and any other person
     whose attendance is necessary given the status of the Project. The
     Developer shall coordinate the production by Architect or others of meeting
     minutes and distribute them to interested parties.

          4.5.4  Developer shall facilitate the flow of communications and
     information among the various participants on the Project and with
     governmental authorities. The Developer shall develop a system for Project
     communications, including, without limitation, meeting minutes, written and
     oral communications, requests for information, cost reports, progress
     reports, submittals, changes, test reports, payment applications, payments,
     logs and other management information necessary to manage the Project. The
     system developed by Developer shall be in the form of a written
     communication system plan (the "Communication System Plan"). The
     Communication System Plan shall include a description of each type of
     communication, the method and form of recording it, frequency, and required
     distribution to various parties. The Communication System Plan shall
     provide that all communications to and from the Contractor (except for
     Contractor's own subcontractors and suppliers) shall go through the
     Developer. The Communication System Plan may include a link on Developer's
     web page which is exclusively devoted to the Project and which will allow
     the exchange of electronic messages to all Project participants, and the
     Communication System Plan shall include a web cam feature on Developer's
     web page that will allow internet users to view the

                                     -15-
<PAGE>

     Project on a real-time basis from one or more cameras at the Project.
     Developer shall review the Communication System Plan with the Contractor
     and shall submit the Communication System Plan to the Owner for written
     approval.

          4.5.5  Within ten (10) days after the end of each month, Developer
     shall submit to Owner the Monthly Report required by Section 7.2 hereof.
     The Developer shall also notify Owner in writing within three (3) days of
     becoming aware of an actual or anticipated cost overrun with respect to any
     major budget category within the Development Budget, and such anticipated
     or actual cost overrun shall also be included in the report. The Developer
     shall also provide Owner with written suggested refinements and supplements
     to the Development Budget as development of the Project moves through its
     various phases. The Development Budget shall not be modified without
     Owner's express written consent.

          4.5.6  Developer shall provide to Owner, in both an electronic and
     hard copy format, updates to the Project Schedule as necessary and in a
     critical-path-method format to reflect changes in the scheduling of the
     Project as more information becomes available during the design, bidding
     and construction phases of the Project, but in no event less than once each
     month; provided, however, in no event shall the Developer have the
     authority to modify the substantial completion and final completion dates
     required with respect to the Project under the Nissan Lease or any critical
     milestone dates of the Project Schedule without written approval by Owner,
     including, but not limited to, any required dates set forth in the
     agreements with the Architect and the Contractor. In addition, the
     Developer shall provide to Owner, during the progress of the Project, a
     written progress report comparing the progress of the Project against the
     Project Schedule.

          4.5.7  Developer shall notify Owner in writing within five (5)
     business days of becoming aware of any actual or anticipated delay in the
     Project Schedule, the Architect's design schedule, or the Contractor CPM
     Schedule.

          4.5.8  The Developer shall review (and shall cause the appropriate
     Owner Consultants to review) all applicable building codes, environmental,
     zoning and land use laws and other applicable local, state and federal
     laws, regulations and ordinances concerning the development, use and
     operation of the Project or any portion thereof. The Developer shall make
     application for and seek to obtain and keep in full force and effect all
     necessary governmental approvals and permits, and shall endeavor to perform
     such acts as shall be reasonably necessary to effect compliance by the
     Owner with all laws, rules, ordinances, statutes, and regulations of any
     governmental authority applicable to the Project. Upon receipt of Owner's
     written request, Developer shall seek to obtain any variances or rezoning
     of such portion of the Land as are necessary or appropriate to cause the
     Project to be in compliance with applicable codes, laws, regulations and
     ordinances. Such services shall be performed at Developer's own cost and
     expense, except that all out-of-pocket costs and costs of attorneys and
     consultants incurred in any such efforts shall be borne by Owner.

                                     -16-
<PAGE>

          4.5.9   Developer shall advise Owner with respect to all dealings with
     all governmental authorities who have control over the development of the
     Project and the construction of all improvements Owner authorizes in
     writing to be constructed on the Project, including advising Owner with
     respect to the contest by Owner of any law, regulation or rule which Owner
     deems to adversely affect the Project.

          4.5.10  The Developer shall review all applicable private
     restrictions, covenants and easement agreements concerning the development,
     use and operation of the Project or any portion thereof, including the
     Declaration of Covenants, Restrictions and Development Standards Applicable
     to DFW Freeport dated October 29, 1979, recorded in Volume 79212, page
     2965, Dallas County Records, as supplemented and amended (the "CC&R"). The
     Developer shall endeavor to perform such acts as shall be reasonably
     necessary to effect compliance by the Owner with all such restrictions,
     covenants and easements, including without limitation the timely submittal
     of plans and specifications with respect to the Project to the
     Architectural Control Committee established under the CC&R and obtaining
     all requisite approvals required to be obtained with respect to the Project
     under the CC&R.

          4.5.11  The Developer shall negotiate and submit to the Owner for the
     Owner's approval all contracts for, or otherwise arrange for the delivery
     of, on a timely basis, all utilities required for the development,
     construction, and operation of the Project, including, without limitation,
     water, electricity, telephone, storm sewer, and sanitary sewer services.

          4.5.12  As Owner's representative, Developer shall supervise,
     administer, coordinate and manage the performance of the Contractor, the
     Architect, and the other Owner Consultants under their respective contracts
     with Owner, and Developer shall give or make Owner's instructions,
     requirements, and approvals provided for in such contracts after obtaining
     Owner's written approval with respect thereto.

          4.5.13  The Developer shall coordinate the services of such
     accountants and attorneys as may be engaged by the Owner upon such terms as
     may be approved by the Owner and utilize such accounting and disbursement
     systems as may be determined by the Owner.

          4.5.14  The Developer shall review and make recommendations to the
     Owner regarding the Owner's insurance program so that the Owner shall
     obtain and keep in force, at the Owner's expense as contemplated in the
     Development Budget, such policies of insurance, including, but not limited
     to, public liability, all-risk, and builder's risk, in such amounts and
     with such carriers as shall be prudent with respect to the Project.

          4.5.15  The Developer will work with Owner in good faith to satisfy
     the underwriting, closing and ongoing monitoring requirements of any lender
     providing financing for the acquisition and construction of the Project.

                                     -17-
<PAGE>

          4.5.16  The Developer shall prepare and deliver to the Owner for
     Owner's approval all construction draw requests under any construction loan
     obtained by the Owner with respect to the Project, such draw requests to be
     in form and content sufficient to permit the lender to approve or
     disapprove such requests, and after approval of the draw request by Owner,
     Developer shall cause same to be delivered to the lender.

          4.5.17  The Developer shall cooperate with the Owner's inspecting
     engineer, if any, and/or Owner's lender's inspection engineer, if any,
     engaged for the purpose of reviewing the status of the work.

          4.5.18  The Developer shall coordinate, review, administer, manage and
     oversee the work and activities relating to, and the performance of, the
     Tenant Improvements to be constructed and installed by the "Landlord" under
     the Nissan Lease.

          4.5.19  The Developer shall deliver to the Owner copies of all
     permits, licenses, guaranties, warranties, bills of sale and other
     contracts, agreements, change orders or commitments obtained or received by
     the Developer for the account or benefit of the Owner. Developer will keep
     all originals of such documents in the Project file and deliver such
     originals to Owner promptly after the Completion Date.

          4.5.20  Following the Completion Date, Developer shall use
     commercially reasonable efforts to obtain a release of the repurchase
     option reserved by The Ruth Ray and H. L. Hunt Foundation and The Ruth
     Foundation (collectively "Seller") in the Special Warranty Deed from Seller
     to Owner, which release shall be in form suitable for recording in the
     Dallas County Records.

          4.5.21  Developer shall take whatever actions are necessary and
     appropriate to accomplish completion of the Project in accordance with the
     approved Project Schedule and within the approved Development Budget.

          4.5.22  The Developer shall perform and discharge all other
     obligations of the Developer under this Agreement.

     4.6  Completion.  The Developer hereby agrees to diligently use
          ----------
commercially reasonable efforts and shall devote sufficient time and personnel
to cause the development of the Project to be completed in compliance with the
time parameters established therefor under the Nissan Lease, and in accordance
with the Development Budget as it may from time to time be revised pursuant to
Section 5.2 hereof.

     4.7  Employees.  The Developer shall have in its employ at all times a
          ---------
sufficient number of capable employees to enable the Developer to perform its
duties hereunder.  The individual development managers designated by the
Developer to be dedicated to the Project and who shall be principally
responsible for performing the Development Functions shall be subject to the
reasonable approval of the Owner.  Owner hereby acknowledges its approval of the
following individuals as development managers principally responsible for
performing the Development Functions:  Jeffrey L. Swope, Stephen M. Modory,
Robert D. Poynor, and Jim

                                     -18-
<PAGE>

Stewart. Any substitute development manager shall also be subject to the
reasonable approval of the Owner. All persons, other than independent
contractors, employed by the Developer in the performance of its
responsibilities hereunder shall be exclusively controlled by and shall be the
employees of the Developer and not of the Owner, and the Owner shall have no
liability, responsibility or authority with respect thereto.

     4.8  Developer's Costs.  Notwithstanding anything contained in any other
          -----------------
provision of this Agreement to the contrary, the following costs and expenses
shall be borne solely by the Developer and shall not be borne by the Owner:

          (a)  Cost of gross salary and wages, payroll taxes, insurance,
     workers' compensation and other benefits of any employees of the Developer;

          (b)  Cost of forms, papers, ledgers and other supplies and equipment
     used in the Developer's office;

          (c)  Cost of electronic data processing or computer services, or any
     pro rata charge for data processing or computer services provided by
     computer service companies, which the Developer may elect to incur in the
     performance of the Development Functions;

          (d)  Cost of office equipment acquired by the Developer to enable it
     to perform its duties hereunder;

          (e)  Cost of advances made to employees of the Developer and cost of
     travel and lodging by the Developer's employees and agents, except as
     provided in Section 11.5 hereof; and

          (f)  Cost attributable to losses, including any legal fees relating
     thereto, arising from negligence, fraud or willful act or omission on the
     part of the Developer or any of the Developer's officers, directors,
     employees or agents, except to the extent such costs are to be borne by the
     Owner pursuant to Section 9.3 hereof.

                                   ARTICLE 5
                                   ---------
                              DEVELOPMENT BUDGET
                              ------------------

     5.1  Implementation of Development Budget.  The Owner hereby approves the
          ------------------------------------
Development Budget and the Developer is hereby authorized and directed to
implement the Development Budget pursuant to this Agreement. The Developer may,
without the need for any further approval whatsoever by the Owner, make any
expenditures and incur any obligations provided for in the Development Budget,
as it may be revised from time to time as provided herein. The Developer shall
use prudence and diligence and shall employ commercially reasonable efforts to
ensure that the actual costs incurred for each category or line item of expense
as set forth in the Development Budget shall not exceed such category or line
item in the Development Budget. The Developer shall advise the Owner promptly if
it appears that costs in

                                     -19-
<PAGE>

any category or line item specified in the Development Budget will exceed the
amount budgeted therefor. All expenses shall be charged to the proper category
or line item in the Development Budget, and no expenses may be classified or
reclassified for the purpose of avoiding an excess in the budgeted amount of a
category or line item without the Owner's prior written approval; provided,
however, Developer may make an allocation of up to 33 1/3% of the "Landlord
Contingency" line item in the Development Budget to other categories or line
items (other than payments to Developer) without Owner's prior written approval.
Except for the allocation of up to 33 1/3% of the "Landlord Contingency" line
item in the Development Budget to other categories or line items as provided in
the preceding sentence, the Developer shall secure the Owner's prior written
approval before incurring and paying any cost which will result in aggregate
expenditures under any one category or line item in the Development Budget
exceeding the amount budgeted therefor.

     5.2  Revision of Development Budget.  If the Developer at any time
          ------------------------------
determines that the Development Budget is not compatible with the then-
prevailing status of the Project and does not adequately provide for the
completion of the Project, the Developer shall promptly prepare and submit to
the Owner an appropriate revision of the Development Budget. Any such revision
shall require the approval of the Owner; provided, however, that any such
revision shall be considered approved on the fourteenth (14th) day following its
delivery to the Owner, unless the Owner shall, within such fourteen (14) day
period, notify the Developer in writing of its disapproval of the proposed
revision and specify in such notice the items to which it objects. In the event
of any such objection, the Developer and the Owner shall consult and endeavor to
reconcile their differences.

     5.3  Emergencies.  Notwithstanding any limitations herein provided, the
          -----------
Developer may spend funds or incur expenses on behalf of the Owner in
circumstances which the Developer reasonably and in good faith believes
constitute an emergency requiring prompt action to avert, or reduce the risk of,
damage to persons or property. The Developer shall, in any case, notify the
Owner as soon as practicable of the existence of such emergency and of the
action taken by the Developer with respect thereto.

     5.4  Reduction in Fees.  If the Total Project Costs shall exceed the
          -----------------
Capitalized Rent Amount (as hereinafter defined), the amount of the fees payable
to the Developer under Sections 11.2 through 11.4 hereof shall be reduced by the
amount of such excess, with any reductions to be applied to such fees in the
following order of priority:

          (a)  first, to unpaid portions of the Development Fee until the
     remaining Development Fee is reduced to zero;

          (b)  then to unpaid portions of the Tenant Occupancy Fee until the
     remaining Tenant Occupancy Fee is reduced to zero;

          (c)  then to any portion of the Development Fee and the Tenant
     Occupancy Fee which has theretofore been paid to the Developer until all
     such fees have been reduced to zero, and the Developer hereby agrees to
     reimburse to the Owner an amount of such fees theretofore paid to the
     Developer as shall equal the amount of such reduction;

                                     -20-
<PAGE>

          (d)  then to any portion of the Leasing Fee which has theretofore been
     paid to the Developer until all such fees have been reduced to zero, and
     the Developer hereby agrees to reimburse to the Owner an amount of such
     Leasing Fee theretofore paid to the Developer as shall equal the amount of
     such reduction.

The aforesaid reductions in the fees payable to the Developer under Sections
11.2 through 11.4 hereof shall be effected regardless of whether or not
appropriate revisions of the Development Budget are approved by the Owner and
regardless of whether or not any increases in costs and expenses incurred by the
Owner with respect to the acquisition of the Land or the designing, engineering,
planning, development, construction, installation, completion, leasing and
financing of the Project are approved by the Owner; provided, however, in the
                                                    --------  -------
event such costs and expenses shall increase as a result of a change by the
Owner in the scope of the work comprising the Project, the incremental costs due
to the change in the scope of the work shall not cause a reduction in the fees
payable to the Developer under Sections 11.2 through 11.4 hereof.  The Owner
shall not be obligated to accept or agree to changes in the scope of the work
comprising the Project in order to reduce the costs and expenses with respect
thereto. The Owner and the Developer agree that appropriate reductions in the
fees payable to the Developer (and reimbursements thereof to the Owner, if
applicable) shall be effected as and when it is reasonably determined by the
Owner that the costs and expenses under any category or line item in the
Development Budget shall exceed the amount originally budgeted therefor or that
costs and expenses will be incurred that are not originally budgeted under the
Development Budget; provided, however, the Owner and the Developer shall make
reasonable allocations of the "Landlord Contingency" line item in the
Development Budget to other categories or line items prior to effecting a
reduction in the fees payable to the Developer, so long as a reasonable reserve
is maintained in the "Landlord Contingency" line item to cover future
contingencies. Promptly following the Completion Date, the Owner and the
Developer shall make any final adjustments and payments between them to give
effect to the agreements set forth in this Section 5.4. For purposes hereof, the
term "Capitalized Rent Amount" shall mean the amount calculated by dividing the
Base Rent amount payable by Nissan under the Nissan Lease for the first twelve
(12) months of the initial term of the Nissan Lease (taking into account any
adjustment in the amount of Base Rent effectuated pursuant to the last paragraph
of Exhibit "D" to the Nissan Lease, but without taking into account or deducting
any credits against Base Rent to which Nissan is entitled under Paragraphs 2 or
7 of Exhibit "C" attached to the Nissan Lease or under Exhibit "D" attached to
the Nissan Lease) by 0.10.

     5.5  Developer's Obligation for Overage.  If the Total Project Costs shall
          ----------------------------------
exceed the Capitalized Amount by more than the aggregate of the Development Fee,
the Tenant Occupancy Fee and the Leasing Fee, in addition to the foregoing Fees
being reduced to zero (and Developer reimbursing Owner the amount of such Fees
theretofore paid to Developer) as provided in Section 5.4 above, Developer
agrees to pay to the Owner the amount of such overage as and when such overage
amounts are incurred by Developer. No limitation on Developer's liability under
this Agreement, including, without limitation, such limitations set forth in
Sections 4.3.1, 4.3.2, 9.1 and 9.6 hereof, shall affect or limit the obligations
of Developer under Section 5.4 above or this Section 5.5.

                                     -21-
<PAGE>

                                   ARTICLE 6
                                   ---------
                           AUTHORITY OF THE DEVELOPER
                           --------------------------

     6.1  General Authority.  The Developer shall have, and is hereby granted by
          -----------------
the Owner, full and complete power, authority, and discretion to act for, and in
the name, place, and stead of, the Owner in carrying out and discharging the
responsibilities and obligations of the Developer under this Agreement
(including, without limitation, all of the responsibilities imposed upon the
Developer under Article 4 hereof); provided, however, that the Developer shall
have no right or authority, express or implied, to commit or otherwise obligate
the Owner in any manner whatsoever except to the extent specifically provided
herein or specifically authorized in writing by the Owner.

     6.2  Execution of Documents and Agreements.  Only when specifically
          -------------------------------------
authorized by the Owner in a writing to the Developer, the Developer may, at the
Developer's election, execute any documents, agreements, or other instruments on
behalf of the Owner as follows, it being acknowledged that the Developer shall
be entitled to the indemnification by the Owner for any obligations or
liabilities thereunder and shall not thereby incur any liability or obligation
to any third party thereunder:

                         WELLS OPERATING PARTNERSHIP, L.P.,
                         a Delaware limited partnership

                         By:  Champion Partners, Ltd., as development manager

                              By:   Champion Holdings, Ltd., a Texas limited
                                    partnership, its general partner

                                    By:  Champion Interests, Inc., a Texas
                                         corporation, its general partner

                                         By:______________________
                                         Name:____________________
                                         Title:___________________

     6.3  Ratification of Prior Actions of Developer.  Owner hereby acknowledges
          ------------------------------------------
its ratification and approval of the actions of Developer taken prior to the
date hereof and listed on Exhibit "H" attached hereto and by reference made a
                          -----------
part hereof.

                                   ARTICLE 7
                                   ---------
                            ACCOUNTING AND REPORTS
                            ----------------------

     7.1  Books of Account.  The Developer shall maintain or cause to be
          ----------------
maintained true and accurate books of account reflecting the planning, design,
construction, and completion of

                                     -22-
<PAGE>

the Project. All entries to such books of account shall be supported by
sufficient documentation to permit the Owner and its auditors to ascertain that
said entries are properly and accurately recorded. Such books of account shall
be located at the Developer's principal metropolitan Dallas, Texas office and
shall be maintained in accordance with the Developer's present cash method of
accounting, unless otherwise directed or approved by the Owner. The Developer
shall ensure such control over accounting and financial transactions as is
reasonably required to protect the Owner's assets from theft, error or
fraudulent activity on the part of the Developer, the Developer's employees or
agents.

     7.2  Monthly Reports.  Within ten (10) days after the end of each calendar
          ---------------
month, the Developer shall prepare a report with respect to the Project
(hereinafter referred to as the "Monthly Report") and shall cause the same to be
delivered to the Owner and the Owner's inspecting engineer, if any.  Each
Monthly Report shall be subdivided into categories specified in the Development
Budget and shall contain the following information respecting the Project:

          (a)  The draw request for the month covered by the Monthly Report,
     including:

               (i)    each draw request letter;

               (ii)   each certificate of the Architect;

               (iii)  each application and certificate for payment of the
                      Contractor; and

               (iv)   any other invoices covered in the draw request.

          (b)  The costs incurred under the Construction Contract as of the date
     of the Monthly Report.

          (c)  All costs incurred but not paid as of the date of such Monthly
     Report.

          (d)  A comparison of the amount of actual costs incurred as of the
     date of the Monthly Report to the budgeted costs as of such date, shown on
     a line-item basis using the same categories or line items set forth in the
     Development Budget.

          (e)  Photographs of the Project depicting the current status of
     construction.

          (f)  A report with respect to the progress of construction, including
     information as to whether the commencement, milestone and completion dates
     in the Project Schedule and the Nissan Lease are being achieved. The
     Developer shall identify in such report potential variances between the
     completion dates required in the Project Schedule and the Nissan Lease and
     the probable completion dates and shall make recommendations as to
     adjustments necessary to meet the required completion dates.

     The Developer shall furnish the Owner with a certificate from Developer in
respect of each such Monthly Report certifying that to the best of Developer's
knowledge, such Monthly Report is accurate, true and complete in all respects.

                                     -23-
<PAGE>

     7.3  Annual Development and Financial Statements.  Within thirty (30) days
          -------------------------------------------
after the end of each fiscal year of the Owner during the term of this
Agreement, the Developer shall cause to be prepared and delivered to the Owner,
at the Owner's expense, a report which is a summary of the previous Monthly
Reports for such fiscal year which have been tendered to the Owner pursuant to
Section 7.2 hereof.  In addition, within sixty (60) days after the end of each
fiscal year of the Owner during the term of this Agreement, the Developer shall
cause to be prepared and delivered to the Owner, at the Owner's expense,
unaudited financial statements reflecting all receipts and disbursements
collected, received, or made by the Developer with respect to the development
and the construction of the Project for such fiscal year.  The Developer shall
also cause to be prepared and delivered to the Owner such other reports and
information with respect to the development and construction of the Project for
each fiscal year as the Owner shall reasonably request.

     7.4  Examination of Books and Records.  The Owner, at its expense, shall
          --------------------------------
have the right at all reasonable times during normal business hours and upon at
least twenty-four (24) hours advance notice, to audit, to examine, and to make
copies of or extracts from the books of account and records maintained by the
Developer with respect to the Project.  If the Owner shall notify the Developer
of either weaknesses in internal control or errors in record keeping, the
Developer shall correct such weaknesses and errors as soon as possible after
they are disclosed to the Developer.  The Developer shall notify the Owner in
writing of the actions taken to correct such weaknesses and errors.

                                   ARTICLE 8
                                   ---------
                                    BANKING
                                    -------

     8.1  Separate Accounts.  It is contemplated that the Owner will make
          -----------------
disbursements with respect to the development and construction of the Project
directly to the Architect (if applicable) and the Contractor.  Nevertheless, all
disbursements and other funds of the Owner which may be received by the
Developer hereunder with respect to the development or construction of the
Project shall be deposited by the Developer and held in such bank account or
accounts maintained by the Developer in such bank or banks with federal deposit
insurance protection as may be selected by the Developer and approved by the
Owner.  All such funds shall be and shall remain the property of the Owner and
shall be disbursed by the Developer in payment of the obligations of the Owner
incurred in connection with the development and construction of the Project, or,
subject to the provisions of Section 8.2 below, shall be disbursed to the Owner
at the Owner's request.  Except as hereinafter provided, the Developer shall not
commingle the Owner's funds with the funds of any other person.

     8.2  The Owner's Duty to Provide Funds.  The Owner agrees that the Owner
          ---------------------------------
will pay all current obligations of the Owner in accordance with the Development
Budget, including all obligations of the Owner to the Developer hereunder.
Alternatively, at the Owner's option, the Owner may elect to provide funds to
the Developer so that the Developer can pay all such obligations of the Owner
(excluding obligations to the Developer, it being understood and agreed that
such obligations to the Developer shall be paid directly by the Owner to the
Developer).  If

                                     -24-
<PAGE>

the Owner elects to cause the Developer to make payment of such obligations, the
Owner hereby agrees that, by making deposits to (following notice as provided
below), or by refraining from withdrawing funds from, the bank account or
accounts maintained by the Developer pursuant to Section 8.1 above, the Owner
shall, during the term of this Agreement, maintain sufficient funds in such bank
account or accounts to enable the Developer to pay all current obligations of
the Owner in accordance with the Development Budget, excluding the obligations
of the Owner to the Developer hereunder. Accordingly, the Owner shall, within
ten (10) days of its receipt of any written request from the Developer for
additional funds (which request must specify the amount of such funds requested
and the purposes for which they are to be used), deposit in such bank account or
accounts such additional funds as the Owner shall consider appropriate with
respect to such request by the Developer.

     8.3  Investment of Owner's Funds.  If at any time there are in the bank
          ---------------------------
account or accounts established pursuant to Section 8.1 above, funds of the
Owner, from whatever sources, temporarily exceeding the immediate cash needs of
the Project, the Developer may (and at the discretion of the Owner shall) invest
such excess funds in such savings accounts, certificates of deposit, United
States Treasury obligations, commercial paper, and the like, as the Developer
shall deem appropriate or as the Owner shall direct, provided that the form of
any such investment shall be consistent with the Developer's need to be able to
liquidate any such investment to meet the cash needs of the Project from time to
time.

                                   ARTICLE 9
                                   ---------
                         STANDARD OF CARE; LIABILITY;
                         ----------------------------
                          INDEMNITY; CONFIDENTIALITY
                          --------------------------

     9.1  Standard of Care; Developer's Liability.  The Developer shall have no
          ---------------------------------------
liability to the Owner for any errors of judgment, or any mistakes of fact or of
law, made in a good faith effort to perform and carry out the Developer's
responsibilities under this Agreement, unless the Developer has failed to
exercise that degree of care and skill required of the Developer under Section
2.1 hereof, provided, of course, that sufficient funds are made available by the
Owner for the performance of the Developer's responsibilities.

     9.2  Indemnity of Owner.  The Developer hereby agrees to indemnify, defend
          ------------------
and hold harmless the Owner and its partners and their respective officers,
directors and employees, from and against any and all claims, demands, losses,
liabilities, actions, lawsuits and other proceedings, judgments and awards, and
costs and expenses (including without limitation reasonable attorneys' fees and
court costs incurred in connection with the enforcement of this indemnity or
otherwise), arising out of the gross negligence, fraud or any willful act or
omission of the Developer, or any of its officers, directors, agents or
employees, in connection with this Agreement or the Developer's services or work
hereunder, whether within or beyond the scope of its duties or authority
hereunder.

     9.3  Indemnity of Developer.  The Owner hereby agrees to indemnify, defend
          ----------------------
and hold harmless the Developer, its officers, directors and employees, from and
against any and all claims, demands, losses, liabilities, actions, lawsuits and
other proceedings, judgments and

-25-
<PAGE>

awards, and costs and expenses (including without limitation reasonable
attorney's fees and court costs incurred in connection with the enforcement of
this indemnity or otherwise), arising out of (i) any action taken by the
Developer within the scope of its duties or authority hereunder, excluding only
such of the foregoing as result from the negligence, fraud or willful act of the
Developer, its officers, directors, agents and employees, and (ii) the gross
negligence, fraud or any willful act or omission of the Owner and its partners
and their respective officers, directors and employees.

     9.4  Survival of Indemnities.  The provisions of Sections 9.2 and 9.3
          -----------------------
hereof shall survive the completion of the Developer's services hereunder or any
earlier termination of this Agreement.

     9.5  No Obligation to Third Parties.  None of the responsibilities and
          ------------------------------
obligations of the Developer under this Agreement shall in any way or in any
manner be deemed to create any liability of the Developer to, or any rights in,
any person or entity other than the Owner.

     9.6  Nature of the Developer's Duties and Responsibilities.  The Owner
          -----------------------------------------------------
hereby acknowledges that the Developer's duties and responsibilities hereunder
with respect to the development and construction of the Project consist only in
managing, supervising, and coordinating the planning, design, construction and
completion of the Project and the performance of the other Development Functions
in accordance with the terms of this Agreement; that the Developer is not itself
preparing any architectural or engineering plans, designs, or specifications or
performing any construction required for the development or completion of the
Project; that the Developer is not a guarantor or insurer of any work to be
performed by any other party in connection with the planning, design,
construction, and completion of the Project; and that the Developer is not
responsible for, and will not be liable for, any work, act, omission,
negligence, gross negligence, or intentional misconduct of any other party
employed by the Owner or performing work for the Owner in connection with the
Project.

     9.7  Ownership of Information and Materials.  The Owner shall have the
          --------------------------------------
right to use, without further compensation to the Developer, all written data
and information generated by or for the Developer in connection with the Project
or supplied to the Developer by the Owner or the Owner's contractors or agents,
and all drawings, plans, books, records, contracts, agreements and all other
documents and writings in its possession relating to its services or the
Project.  Such data and information shall at all times be the property of the
Owner.  The Developer agrees, for itself and all persons retained or employed by
the Developer in performing its services, to hold in confidence and not to use
or disclose to others any confidential or proprietary information of the Owner
which is heretofore or hereafter disclosed to the Developer or any such persons
and which is designated by the Owner as confidential and proprietary, including
but not limited to any proprietary or confidential data, information, plans,
programs, plants, processes, equipment, costs, operations, tenants or customers
which may come within the knowledge of the Developer or any such persons in the
performance of, or as a result of, its services, except where (i) the Owner
specifically authorizes the Developer to disclose any of the foregoing to others
or such disclosure reasonably results from the performance of the Developer's
duties hereunder, or (ii) such written data or information shall have
theretofore been made publicly available by parties other than the Developer or
any such persons, or (iii) Developer is required by law to disclose

                                     -26-
<PAGE>

such information (provided that in such case Developer shall give Owner prior
notice of the request for disclosure and shall cooperate with Owner in obtaining
a protective order or other remedy at Owner's expense). Nothing contained in
this Section 9.7 shall be deemed to limit or restrict the provisions of Article
14 hereof or of the rights of the Developer thereunder.

                                   ARTICLE 10
                                   ----------
                                   INSURANCE
                                   ---------

     10.1 Insurance Requirements.  Throughout the term of this Agreement,
          ----------------------
insurance with respect to the Project shall be carried and maintained in force
in accordance with the provisions contained in Exhibit "C", attached hereto and
                                               -----------
incorporated herein by this reference, with the premiums and other costs and
expenses for such required insurance to be borne as provided in Exhibit "C".
                                                                -----------

     10.2 Waiver of Subrogation.  Owner, on behalf of itself and its insurers,
          ---------------------
waives its rights of recovery against Developer or Developer's partners and
their respective officers, directors and employees, for damages sustained by
Owner as a result of any damage to any property arising from any risk or peril
generally covered or coverable by any insurance policy actually carried by or
required to be carried by Owner pursuant to the terms of this Agreement,
regardless of cause, including negligence; and Owner agrees that no party shall
have any such right of recovery by way of subrogation or assignment.  Developer,
on behalf of itself and its insurers, waives its rights of recovery against
Owner and Owner's partners and their respective officers, directors and
employees, for damages sustained by Developer as a result of any damage to any
property arising from any risk or peril generally covered or coverable by any
insurance policy actually carried by or required to be carried by Developer
pursuant to the terms of this Agreement, regardless of cause, including
negligence; and Developer agrees that no party shall have any such right of
recovery by way of subrogation or assignment.  Owner and Developer shall each
notify their respective insurance carriers of the mutual waivers herein
contained and shall cause their respective insurance policies required hereunder
to be endorsed, if necessary, to prevent any invalidation of coverage as a
result of the mutual waivers herein contained.

                                  ARTICLE 11
                                  ----------
                         COMPENSATION OF THE DEVELOPER
                         -----------------------------

     11.1 Fees - General.  As compensation for the services rendered and to be
          --------------
rendered by the Developer under this Agreement, the Owner shall pay the
Developer the Development Fee, the Leasing Fee, and the Tenant Occupancy Fee,
all in accordance with and subject to the terms and provisions of Sections 11.2,
11.3, and 11.4 hereof, respectively, and all such Fees shall be subject to
reduction as provided in Section 5.4 hereof.

     11.2 Development Fee.  The Owner shall pay the Developer, as the
          ---------------
Development Fee for the Project, the sum of  One Million Two Hundred Fifty
Thousand and No/100 Dollars ($1,250,000.00).  The Development Fee shall be paid
in monthly installments commencing with the month following the month during
which the Owner acquires the Land.  The monthly

                                     -27-
<PAGE>

installments shall be $50,000 for each of the first four (4) months and then
$75,000 for each of the twelve (12) months thereafter; provided, however, in the
event of any actual or anticipated delay in the progress of the Project of more
than one (1) month from the scheduled progress of the Project as set forth on
the original Project Schedule, the amount of the aforesaid monthly installments
shall be appropriately adjusted to take such delay into account. The $150,000
remaining balance of the Development Fee shall be due and payable upon the
Completion Date, and as a condition precedent to the payment of such remaining
balance, Developer shall submit to Owner the following: (a) fully executed,
unconditional, final lien waiver and release from Developer in the form attached
hereto as Exhibit "G", and (b) fully executed, unconditional, final lien and
          -----------
claim waiver and releases from the Contractor and all subcontractors performing
work or supplying labor or materials in connection with the Project.  The
Development Fee shall be subject to reduction as provided in Section 5.4 hereof.

     11.3 Leasing Fee.  With respect to the Nissan Lease, Owner shall pay to the
          -----------
Developer, as the Leasing Fee with respect to the Nissan Lease, and as full and
complete compensation for all leasing services provided by the Developer in
connection with such Nissan Lease, an amount equal to One Million and No/100
Dollars ($1,000,000.00).  Such Leasing Fee shall be due and payable at such time
as the Owner shall make the initial disbursement of funds following the
commencement of on-site development work with respect to the Project and the
acquisition by Owner of the Land.  The Leasing Fee shall be subject to reduction
as provided in Section 5.4 hereof.

     11.4 Tenant Occupancy Fee.  The Owner shall pay the Developer, as the
          --------------------
Tenant Occupancy Fee,  an amount determined by first calculating the positive
difference, if any, between the Capitalized Rent Amount and the Total Project
Costs, and then subtracting from such difference the amount of the Reserve
Account, if any.  The amount of Tenant Occupancy Fee as so determined shall be
subject to increase as provided in Exhibit "I" attached hereto.  The amount of
                                   -----------
Tenant Occupancy Fee shall be subject to reduction as provided in Section 5.4
hereof, and, in addition, the Owner shall have the right to offset against the
Tenant Occupancy Fee the amount of any payment due from Developer to Owner under
Section 12.1 hereof.  The Tenant Occupancy Fee (excluding any portion deferred
pursuant to Exhibit "I" attached hereto) shall be due and payable in one lump
            -----------
sum upon the Completion Date and the final calculation of the Total Project
Costs; provided, however, if any Punchlist items shall remain to be cured,
corrected or completed at such time as the Tenant Occupancy Fee shall be due and
payable, Owner shall have the right to withhold from the payment of the Tenant
Occupancy Fee an amount which, when combined with the retainage amount withheld
from the Contractor to assure performance and completion of such Punchlist
items, shall be equal to 200% of the estimated cost to cure, correct or complete
such Punchlist items, and the amount held back from Developer shall be paid to
Developer only after the Punchlist items have been fully cured, corrected or
completed (or shall otherwise be available to pay the costs of curing,
correcting or completing such Punchlist items).  As a condition precedent to the
payment of the Tenant Occupancy Fee, Developer shall submit to Owner the
following:  (a) fully executed, unconditional, final lien waiver and release
from Developer in the form attached hereto as Exhibit "G", and (b) fully
                                              -----------
executed, unconditional, final lien and claim waiver and releases from the
Contractor and all subcontractors performing work or supplying labor or
materials in connection with the Project.

                                     -28-
<PAGE>

     11.5 Reimbursement of Costs.  In addition to the Fees payable under
          ----------------------
Sections 11.2, 11.3 and 11.4 above, and subject to the limitations imposed by
the Development Budget, Owner agrees to reimburse Developer for all reasonable
and verifiable out-of-pocket expenses incurred by Developer for costs of prints,
reproductions, telephone, telegrams, postage, and couriers, for costs of in-town
travel by personal automobile at the then current reimbursement rate allowed
under the Internal Revenue Code and regulations, and for out-of-town travel when
authorized in advance and in writing by Owner.  The amounts to be reimbursed by
Owner pursuant to this Section 11.5 shall be paid monthly after receipt by Owner
of a bill therefor accompanied by supporting statements or invoices, or if such
supporting documentation is not available due to the nature of the cost or
expense incurred, an explanation in reasonable detail from Developer of the
costs and expenses to be reimbursed.  The first such reimbursement by Owner
pursuant to this Section 11.5 shall be paid at such time as the Owner shall make
the initial disbursement of funds following the commencement of on-site
development work with respect to the Project and the acquisition by Owner of the
Land.

     11.6 Disbursements to the Developer.  The Developer may not disburse to
          ------------------------------
itself any amounts due under this Article 11 from the bank account or accounts
maintained by the Developer pursuant to Article 8 hereof, it being understood
and agreed that the amounts due and payable to the Developer under this Article
11 shall be paid directly by the Owner to the Developer.

                                  ARTICLE 12
                                  ----------
         RENT CREDITS; REIMBURSEMENTS OF ADVANCES, COSTS AND EXPENSES
         ------------------------------------------------------------

     12.1 Payment by Developer of Rent Credits.  If Tenant is entitled to any
          ------------------------------------
credit against Base Rent under Paragraphs 2 and/or 7 of Exhibit "C" attached to
the Nissan Lease and/or under Exhibit "D" attached to the Nissan Lease, the
Developer shall pay to the Owner the amount of such credit.  To the extent there
exists any Tenant Occupancy Fee not yet funded to Developer, such payment by the
Developer to the Owner shall be effectuated by means of a credit against such
unfunded Tenant Occupancy Fee until such Tenant Occupancy Fee is reduced to
zero, and any remaining such payment by the Developer to the Owner shall be due
and payable upon the date(s) that such rent credits are actually effectuated by
Nissan against the Base Rent payable under the Nissan Lease.

     12.2 Reimbursement by Owner of Advances.  The Developer shall not be
          ----------------------------------
required to advance any of its own funds for the payment of any costs and
expenses incurred by or on behalf of the Owner in connection with the Project,
but if the Developer advances its own funds in payment of any of such costs and
expenses, the Owner, subject to the provisions of Sections 4.8, 5.2 and 11.6
hereof, shall promptly reimburse the Developer.

     12.3 Reimbursement by Owner of Costs and Expenses.  At such time as the
          --------------------------------------------
Owner shall make the initial disbursement of funds following the commencement of
on-site development work with respect to the Project and the acquisition by
Owner of the Land, the Owner shall reimburse the Developer for all costs and
expenses set forth on Exhibit "D" attached hereto and by this reference made a
                      -----------
part hereof, all of which costs and expenses the Developer

                                     -29-
<PAGE>

hereby represents and warrants were incurred and paid by the Developer prior to
the date hereof (or will be paid by the Developer in due course) in connection
with the Project and are authorized and bona fide expenditures under the
Development Budget.

                                   ARTICLE 13
                                   ----------
                            DEFAULT AND TERMINATION
                            -----------------------

     13.1 Default by Developer.  Upon the happening of any Event of Default (as
          --------------------
hereinafter defined), the Owner shall have the absolute unconditional right to
terminate this Agreement by giving written notice of such termination to the
Developer.  Any one or more of the following events shall constitute an "Event
of Default" by the Developer under this Agreement:

          (a)  If the Developer shall fail to observe, perform or comply in any
     material respect with any term, covenant, agreement or condition of this
     Agreement which is to be observed, performed or complied with by the
     Developer under the provisions of this Agreement, and such failure shall
     continue uncured for twenty (20) days after the giving of written notice
     thereof by the Owner to the Developer specifying the nature of such
     failure, unless such failure can be cured but is not susceptible of being
     cured within said twenty (20) day period, in which event such a failure
     shall not constitute an Event of Default if the Developer commences
     curative action within said twenty (20) day period, and thereafter
     prosecutes such action to completion with all due diligence and dispatch;

          (b)  If the Developer shall make a general assignment for the benefit
     of creditors;

          (c)  If any petition shall be filed against the Developer in any
     court, whether or not pursuant to any statute of the United States or of
     any State, in any bankruptcy, reorganization, dissolution, liquidation,
     composition, extension, arrangement or insolvency proceedings, and such
     proceedings shall not be dismissed within sixty (60) days after the
     institution of the same, or if any such petition shall be so filed by the
     Developer;

          (d)  If, in any proceeding, a receiver, trustee or liquidator be
     appointed for all or a substantial portion of the property and assets of
     the Developer, and such receiver, trustee or liquidator shall not be
     discharged within ninety (90) days after such appointment;

          (e)  If the Developer shall assign this Agreement or any of its rights
     or obligations hereunder, without the prior written consent of the Owner;
     and

          (f)  If the Developer shall intentionally or willfully fail to perform
     any of its duties or obligations hereunder, or if the Developer shall
     misappropriate any funds of the Owner in the possession or control of the
     Developer or shall otherwise commit an act of fraud against the Owner
     (except that if such misappropriation of funds or fraud by the

                                     -30-
<PAGE>

     taking is committed by an employee of the Developer, such event may be
     cured by the Developer if the Developer makes prompt restitution to the
     Owner and discharges such employee).

     13.2 Additional Terminating Event.  The Owner shall have the right to
          ----------------------------
terminate this Agreement upon written notice to the Developer in the event the
Owner shall elect for any reason whatsoever not to acquire the Land.

     13.3 Default by Owner.  If the Owner fails to comply with or perform in any
          ----------------
material respect any of the terms and provisions to be complied with or any of
the obligations to be performed by the Owner under this Agreement, and such
failure continues uncured for a period of twenty (20) days after written notice
to the Owner specifying the nature of such default (or, in the case of a non-
monetary default, such longer period of time as may be needed in the exercise by
the Owner of due diligence to effect a cure of any such non-monetary default),
then the Developer shall have the right, in addition to all other rights and
remedies available to the Developer at law and in equity (including without
limitation the right to pursue an action for specific performance), at its
option, to terminate this Agreement by giving written notice thereof to the
Owner, in which event the Owner shall immediately pay to the Developer, in cash,
(i) the sums payable to the Developer upon termination as provided in Section
13.4 hereof, and (ii) the Tenant Occupancy Fee, and upon the payment of such
amounts, subject to Sections 9.2, 9.3, 9.7, and 13.5 hereof, the Owner and the
Developer shall have no further rights, duties, liabilities or obligations
whatsoever under this Agreement.

     13.4 Obligation for Fees Upon Termination.  Upon any termination of this
          ------------------------------------
Agreement, the Owner shall pay to the Developer all amounts due and payable to
the Developer as of the date of termination pursuant to the terms of this
Agreement (including, without limitation, any accrued but unpaid installments of
the Development Fee) less, if this Agreement terminates as a result of an Event
                     ----
of Default, an amount equal to the damages incurred or suffered (or to be
incurred or suffered) by the Owner as a result of such Event of Default.  Upon
the payment of all such amounts payable under this Section, subject to Sections
9.2, 9.3, 9.7, and 13.5 hereof, the Owner and the Developer shall have no
further rights, duties, liabilities or obligations whatsoever under this
Agreement.

     13.5 Actions Upon Termination.  Upon any termination of this Agreement, the
          ------------------------
Developer shall promptly (a) account for and deliver to the Owner any monies of
the Owner held by the Developer, including funds in the bank account or accounts
maintained by the Developer pursuant to Article 8 hereof and any funds due the
Owner under this Agreement but received after such termination, and (b) deliver
to the Owner or to such other person as the Owner shall designate in writing,
all materials, supplies, equipment, keys, contracts, documents and books and
records pertaining to this Agreement or the development of the Project.  The
Developer shall also furnish all such information, take all such other action
and shall cooperate with the Owner as the Owner shall reasonably require in
order to effectuate an orderly and systematic termination of the Developer's
duties and activities hereunder.  This Section 13.5 of this Agreement shall
survive any termination of this Agreement.

                                     -31-
<PAGE>

     13.6 Interest.  Payments due and unpaid under this Agreement shall bear
          --------
interest from the date which is ten (10) days after the due date thereof until
paid at the prime rate as published in the Wall Street Journal plus two percent
(2%).  The prime rate to be used for the calculation of interest shall be the
prime rate in effect at the time that payment was due.

                                  ARTICLE 14
                                  ----------
                       OTHER ACTIVITIES OF THE DEVELOPER
                       ---------------------------------

     The Owner hereby acknowledges that the Developer is engaged in the
ownership, development, leasing, sale, and management of commercial properties
other than the Project and the Owner hereby agrees that the Developer shall in
no way be restricted from, or have any liability to account to the Owner with
respect to, such activities, notwithstanding that such activities may compete
with, or be enhanced by, the Developer's activities under this Agreement or the
Owner's ownership of the Project.

                                  ARTICLE 15
                                  ----------
                              NATURE OF AGREEMENT
                              -------------------

     The rights and duties granted to and assumed by the Developer hereunder are
those of an independent contractor only.  Nothing contained herein shall be so
construed as to constitute the relationship created under this Agreement between
the Developer and the Owner as a mutual agency, a partnership, or a joint
venture.

                                  ARTICLE 16
                                  ----------
                              GENERAL PROVISIONS
                              ------------------

     16.1 Notices.  Whenever any notice, consent, approval, demand or request
          -------
required or permitted under this Agreement, such notice, consent, approval,
demand or request shall be in writing and shall be delivered by hand or sent by
registered or certified mail, return receipt requested, to the addresses set out
below or to such other addresses as are specified by written notice given in
accordance herewith, or sent via facsimile transmission to the facsimile numbers
set out below or to such other facsimile numbers as are specified by written
notice given in accordance herewith:

     Owner:            Wells Operating Partnership, L.P.
                       c/o Wells Capital, Inc.
                       6200 The Corners Parkway
                       Suite 250
                       Norcross, Georgia  30092
                       Fax: (770) 200-8199
                       Attention:  Mr. Michael C. Berndt

                                     -32-
<PAGE>

     with a copy to:   Troutman Sanders LLP
                       600 Peachtree Street, N.E.
                       Suite 5200
                       Atlanta, Georgia  30308-2216
                       Fax:  (404) 962-6577
                       Attention:  Mr. John W. Griffin

     Developer:        Champion Partners, Ltd.
                       15601 Dallas Parkway
                       Suite 100
                       Addison, Texas  75001
                       Fax:  (972) 490-5599
                       Attention:  Mr. Jeffrey L. Swope

     with a copy to:   Winstead Sechrest & Minick P.C.
                       5400 Renaissance Tower
                       1201 Elm Street
                       Dallas, Texas  75270
                       Fax:  (214) 745-5390
                       Attention:  Mr. T. Andrew Dow

     All notices, consents, approvals, demands or requests delivered by hand
shall be deemed given upon the date so delivered; those given by mailing as
hereinabove provided shall be deemed given on the date on which such notice,
demand, or request is so deposited in the United States Mail; those given by
facsimile transmission shall be deemed given on the first business day following
the date shown on sender's copy thereof showing the proper "answerback" code for
the facsimile transmission number to which the notice is sent.  Nonetheless, the
time period, if any, in which a response to any notice, demand, or request must
be given shall commence to run from the date of receipt of the notice, demand,
or request by the addressee thereof.  Any notice, demand, or request not
received because of changed address of which no notice was given as hereinabove
provided or because of refusal to accept delivery shall be deemed received by
the party to whom addressed on the date of hand delivery or on the third
calendar day following deposit in the United States Mail, as the case may be.

     16.2 Modifications.  Neither any change or modification of this Agreement
          -------------
nor any waiver of any term or condition hereof shall be valid or binding on the
parties hereto, unless such change, modification, or waiver shall be in writing
and signed by the party to be bound thereby.

     16.3 Binding Effect.  This Agreement shall inure to the benefit of and
          --------------
shall be binding upon the parties hereto, their successors, transferees, and
permitted assigns.

     16.4 Duplicate Originals.  For the convenience of the parties hereto, any
          -------------------
number of counterparts hereof may be executed, each such counterpart shall be
deemed to be an original instrument, and all of such counterparts shall together
be deemed one and the same instrument.

                                     -33-
<PAGE>

     16.5 Construction.  This Agreement shall be interpreted, constructed, and
          ------------
enforced in accordance with the laws of the State of Texas.  The titles of the
articles and sections herein have been inserted as a matter of convenience of
reference only and shall not control or affect the meaning or construction of
any of the terms or provisions herein.  The parties agree that they have both
participated equally in the negotiation and preparation of this Agreement and no
court construing this Agreement or the rights of the parties hereunder shall be
prejudiced toward either party by reason of the rule of construction that a
document is to be construed more strictly against the party or parties who
prepared the same.

     16.6 Entire Agreement.  This Agreement is intended by the parties hereto to
          ----------------
be the final expression of their agreement with respect to the subject matter
hereof and is the complete and exclusive statement of the terms thereof
notwithstanding any representation or statement to the contrary heretofore made.

     16.7 Assignment.  This Agreement shall not be assigned by the Developer
          ----------
without the prior written consent of the Owner, and any such assignment by the
Developer without the prior written consent of the Owner shall be null, void and
of no force and effect and shall be an Event of Default hereunder.  This
Agreement shall not be assigned by the Owner without the prior written consent
of the Developer, except that Owner shall have the right at any time to assign
this Agreement or any of its rights or obligations hereunder to any affiliate of
the original Owner or of Wells Capital, Inc. to whom Owner's interest in the
Project is conveyed, provided that no such assignment shall relieve the original
Owner from any obligations under this Agreement.  Upon any such assignment of
this Agreement by Owner or Developer, the assigning party shall cause the
assignee to expressly assume in writing the assigning party's obligations under
this Agreement first arising or accruing after the date of the assignment.

     16.8 Authorized Representatives.  Any consent, approval, authorization, or
          --------------------------
other action required or permitted to be given or taken under this Agreement by
the Developer or the Owner, as the case may be, shall be given or taken by the
authorized representative of each.  For purposes of this Agreement, (a) the
authorized representative of the Developer shall be Jeffrey L. Swope, Stephen M.
Modory, Robert D. Poynor or Jim Stewart; (b) the authorized representative of
the Owner shall be Leo F. Wells, III, Michael C. Berndt or Mike Watson.  Any
party hereto may from time to time designate other or replacement authorized
representatives by written notice from its authorized representative to the
other parties hereto.  The written statements and representations of any
authorized representative of the Developer or the Owner shall for the purposes
of this Agreement be binding upon such party for whom the authorized
representative purports to act, and the other parties hereto shall have no
obligation or duty whatsoever to inquire into the authority of any such
representative to take any action which he proposes to take, regardless of
whether such representative actually has the authority to take any such action;
and the Developer and the Owner shall be entitled to rely upon any direction,
authorization, consent, approval, or disapproval given by any authorized
representative of the Developer or the Owner, as the case may be, in connection
with any matter arising out of or in connection with this Agreement or the
Project.

                                     -34-
<PAGE>

     16.9  Terminology.  All personal pronouns used in this Agreement, whether
           -----------
used in the masculine, feminine, or neuter gender, shall include all other
genders; and all terms used herein in the singular shall include the plural, and
vice versa.

     16.10 Time of Essence.  Time is of the essence of this Agreement.
           ---------------

     IN WITNESS WHEREOF, the parties hereto have executed and sealed this
Agreement as of the day, month and year first above written.

                         "DEVELOPER":
                          ---------

                         CHAMPION PARTNERS, LTD.,
                         a Texas limited partnership

                         By:  Champion Holdings, Ltd., a Texas limited
                              partnership, its general partner

                              By:   Champion Interests, Inc., a Texas
                                    corporation, its general partner

                                    By: /s/ Jeffrey L. Swope
                                       ----------------------------
                                    Name:   Jeffrey L. Swope
                                    Title:  President

                         "OWNER"
                         -------

                         WELLS OPERATING PARTNERSHIP, L.P.,
                         a Delaware limited partnership

                         By:  Wells Real Estate Investment Trust, Inc.,
                              a Maryland corporation, general partner

                              By: /s/ Leo F. Wells III
                                 ---------------------------------
                              Name: Leo F. Wells III
                                   -------------------------------
                              Title: President
                                    ------------------------------

                                     -35-
<PAGE>

                                  EXHIBIT "A"
                                  -----------

             DESCRIPTION OR SITE PLAN OF FEE PARCEL COMPRISING LAND
<PAGE>

                                   EXHIBIT A

BEING a tract of land situated in the CORDELIA BOWEN SURVEY, ABSTRACT NO. 56,
DALLAS County, Texas, and being all of Lot 7, Block C of DFW FREEPORT, 12TH
INSTALLMENT, an Addition to the City of Irving, Texas, recorded in Volume 86246,
Page 317, Deed Records of DALLAS County, Texas, said tract being more
particularly described by metes and bounds as follows:

BEGINNING at a 1/2 inch iron rod with "Halff Assoc., Inc" cap (hereafter
referred to as "with cap") found for corner at the North end of a right of way
corner clip at the intersection of the Northeast right of way line of Esters
Boulevard (80 foot right of way) and the Southeast right of way line of Freeport
Parkway (100 foot right of way);

THENCE North 54 degrees 19 minutes 10 seconds East, with said Southeast right
of way line of Freeport Parkway, a distance of 57.16 feet to a 1/2 inch iron
rod with cap found at the beginning of a curve to the left having a radius of
880.59 feet;

THENCE in a Northerly direction, continuing with said Southeast right of way
line and along said curve to the left, through a central angle of 44 degrees 00
minutes 00 seconds, an arc distance of 676.24 feet to a 1/2 inch iron rod with
cap found for corner;

THENCE North 10 degrees 19 minutes 10 seconds East, continuing along said right
of way line, a distance of 87.55 feet to a 1/2 inch iron rod with cap found for
corner, said point being the Southwest end of a right of way corner clip at the
intersection of said Southeast right of way line of Freeport Parkway and the
Southwest right of way line of Regent Boulevard (100 foot right of way);

THENCE North 55 degrees 19 minutes 10 seconds East, along said right of way
corner clip, a distance of 25.00 feet to a 1/2 inch iron rod with cap found for
corner on said Southwest line of Regent Boulevard;

THENCE South 79 degrees 40 minutes 50 seconds East, along said Southwest right
of way, a distance of 402.27 feet to a 1/2 inch iron rod with cap found at the
beginning of a curve to the right having a radius of 549.97 feet;

THENCE in a Southeasterly direction, continuing with said Southwest right of
way line, along said curve to the right, through a central angle of 43 degrees
56 minutes 10 seconds, an arc distance of 421.73 feet to a 1/2 inch iron rod
with cap found at the end of said curve;

THENCE, South 35 degrees 44 minutes 40 seconds East, continuing with said
Southwest right of way line, a distance of 88.38 feet to a 1/2 inch iron rod
with cap found for corner, said point being the Northern most corner of Lot 6,
Block C of said 12th Installment;

THENCE South 54 degrees 19 minutes 10 seconds West, departing said Southwest
right of way line and along the Northwesterly line of said Lot 6, passing at a
distance of 820.00 feet the Western most corner of Lot 6, also being the
Northern most corner of Lot 9B, Block C, DFW Freeport, 12th Installment
Revision, an Addition to the City of Irving, Texas, recorded in Volume 94036,
Page 4168, Deed Records, DALLAS County, Texas, and continuing along the
Northwesterly line of said Lot 9B, in all a distance of 1208.41 feet to an "X"
cut in concrete set on said Northeast right of way line of Esters Boulevard;

THENCE North 35 degrees 40 minutes 50 seconds West, with said Northeast right of
way line, a distance of 433.97 feet to a 1/2 inch iron rod with cap found at
the South end of the aforementioned corner clip at the intersection of Esters
Boulevard and Freeport Parkway;

THENCE North 09 degrees 19 minutes 10 seconds East, with said right of way
corner clip, a distance of 25.00 feet to the POINT OF BEGINNING and CONTAINING
647,857 square feet or 14.873 acres of land, more or less.

<PAGE>

                                  EXHIBIT "B"
                                  -----------

                               DEVELOPMENT BUDGET

                                                                      AMOUNT
                                                                      ------
Shared Budget Items
-------------------
Land Price (14.873 acres)                                       $ 5,546,000.00
Hard Cost Construction Budget                                    24,150,000.00
A&E Reimbursement to Tenant                                          75,000.00
Architectural & Engineering Costs                                 1,405,000.00
A&E Allowance for CAD Drawings                                       47,400.00
Permits, Fees, Testing, Eng., Legal                                 250,000.00
Property Taxes during Construction                                  100,000.00
                                                                --------------
Subtotal Shared Items                                           $31,573,400.00

Landlord Budget Items
---------------------
Financing Fees and Costs                                        $ 1,053,600.00
Construction Period and Land Interest                             2,153,000.00
Landlord Contingency                                              1,000,000.00
Administrative Costs and Overhead [1]                             4,900,000.00
                                                                --------------
Subtotal Landlord Items                                         $ 9,106,600.00

Tenant Budget Items
-------------------
Tenant Scope Changes Contingency                                $   750,000.00
                                                                --------------
Subtotal Tenant Items                                           $   750,000.00
                                                                --------------

TOTAL PROJECT BUDGET [A]                                        $41,430,000.00

[1] Includes all development and brokerage fees, etc.
<PAGE>

                                  EXHIBIT "C"
                                  -----------

                             INSURANCE REQUIREMENTS

This exhibit is attached to and made part of the Development Agreement between
WELLS OPERATING PARTNERSHIP, L.P., as Owner, and CHAMPION PARTNERS, LTD., as
Developer, dated __________, 2001.

A.   Owner's Insurance Requirements.
     ------------------------------

     Throughout the term of this Agreement the Owner shall carry or cause to be
     carried and maintain in force insurance described in paragraphs 1 through 3
     below. The cost of such policies shall be at the sole cost and expense of
     the Owner.

     1.   Builder's Risk.
          --------------

          An "All Risk" builder's risk policy including coverage for collapse,
          flood, earthquake and installation risks written on a completed value
          basis in an amount not less than total replacement value of the
          Project under construction (less the value of such portions of the
          Project as are uninsurable under the policy, i.e., site preparation,
          abrading, paving, parking lots, etc., excepting, however, foundations
          and other undersurface installations subject to collapse or damage by
          other insured perils). Such policy will also include coverage for soft
          costs including interest expense and loss of rents. Deductible per
          loss shall be determined by the Owner. Such policy will be endorsed to
          waive subrogation against the Developer as provided in Section 10.2 of
          this Agreement.

     2.   Commercial General Liability and Automobile Liability.
          -----------------------------------------------------

          This policy (or policies) shall be written at a total limit of no less
          than $2,000,000 per occurrence and $5,000,000 Aggregate and will
          include the following extension of coverage:

          a.   Broad Form CGL endorsement;
          b.   X, C and U coverage;
          c.   Blanket Contractual with exclusions pertaining to completed
               operations, explosion, collapse and underground hazards deleted.

     3.   Boiler and Machinery.
          --------------------

          If the Boiler and Machinery equipment is put in service prior to the
          expiration of the builder's risk policy and prior to certification of
          building completion the Developer shall notify the Owner so that the
          Owner may exercise its option to purchase Boiler and Machinery
          coverage if needed.
<PAGE>

     B.   Developer's Insurance Requirements for Policies Covering Developer.
          ------------------------------------------------------------------

          During the term of this Agreement, the Developer agrees to carry and
          maintain in force, at the Developer's sole cost and expense, Worker's
          Compensation and Employer's Liability insurance. Such policy shall be
          endorsed to waive subrogation against the Owner as provided in Section
          10.2 of this Agreement.

     C.   Insurance Requirements for Architects and Engineers.
          ---------------------------------------------------

          The Developer shall require any architect or engineering firm employed
          by the Owner to carry Professional Liability Insurance in an amount
          not less than $500,000 per occurrence.

     D.   Insurance Requirements for All Contractors and Third Party Services.
          ---------------------------------------------------------- --------

          Every contractor and all parties furnishing service to the Owner
          and/or the Developer must provide the Developer prior to commencing
          work, evidence of the following minimum insurance requirements. In no
          way do these minimum requirements limit the liability assumed
          elsewhere in this Development Agreement:

          1.   Worker's Compensation and Employers Liability.
               ---------------------------------------------

          2    Commercial General Liability.
               ----------------------------

               a.   Commercial General Liability form, including
                    Premises/Operations, Elevators and Escalators, Independent
                    Contractors, Products - Completed Operations, Personal
                    Injury, (exclusions A and C deleted), Broad Form Property
                    Damage (including Completed Operations), and afford coverage
                    for the X, C and U Hazards.

               b.   Contractual Liability: Blanket basis insuring the liability
                    assumed under this Development Agreement (coverage must be
                    endorsed so that all exclusions relating to watercraft,
                    railroad property, products and completed operations and
                    explosion, collapse and underground hazards are deleted).

               c.   Minimum Limits of Liability: Bodily Injury $500,000 each
                    occurrence, $500,000 aggregate; Property Damage $100,000
                    each occurrence, $1,000,000 aggregate.

          3.   Comprehensive Automobile Liability.
               ----------------------------------

               a.   Comprehensive Automobile Liability form, including all
                    Owned, Non-Owned and Hired Vehicles.

                                      -2-

<PAGE>

               b.   Limits of Liability: Bodily Injury $1,000,000 each person,
                    $1,000,000 each occurrence; Property damage $1,000,000 each
                    occurrence.

          4.   Umbrella Liability.
               ------------------

               Such insurance provide coverage with limits of not less than
               $2,000,000 per occurrence/$2,000,000 aggregate, in excess of the
               underlying coverages listed in 1, 2 and 3 above.

          5.   Additional Requirements.
               -----------------------

               a.   The Contractor shall require the same minimum insurance
                    requirements, as listed above, of all subcontractors, and
                    these subcontractors shall also comply with the additional
                    requirements listed below.

               b.   All insurance coverages required as herein set forth, shall
                    be at the sole cost and expense of contractor,
                    subcontractor, or those providing third party services, and
                    deductibles shall be assumed by, for the account of, and at
                    their sole risk.

               c.   Except where prohibited by law, all insurance policies shall
                    contain provisions that the insurance companies waive the
                    rights of recovery or subrogation against the Owner and the
                    Developer, their agents, servants, invitees, employees,
                    tenants, affiliated companies, contractors, subcontractors,
                    and their insurers.

E.        Miscellaneous.
          -------------

          1.   Accident Reports.
               ----------------

               The Developer shall be completely responsible for reporting to
               the appropriate insurance carriers and/or their agents all
               accidents involving injury to employees of any contractor, any
               member of the public or property damages, provided that the
               Developer receives a report from the Contractor regarding such
               accident or otherwise becomes aware of such accident.

                                      -3-

<PAGE>

                                  EXHIBIT "D"
                                  -----------

                 REIMBURSABLE EXPENDITURES RELATING TO PROJECT
<PAGE>

Exhibit D to Development Agreement
----------------------------------

--------------------------------------------------------------------------------
1) Andrews & Barth                 Legal Fees                       $    135.00
--------------------------------------------------------------------------------
2) Winstead, Sechrest              Legal Fees                       $ 23,814.23
--------------------------------------------------------------------------------
3) Jenkens & Gilchrist             Legal Fees                       $    973.50
--------------------------------------------------------------------------------
4) HBC Engineering                 Phase 1 Environmental            $  1,350.00
--------------------------------------------------------------------------------
5) Reed Engineering                Geotechnical/Soils               $  4,500.00
--------------------------------------------------------------------------------
6) Thomas Reprographics            Various Copies                   $  1,741.09
--------------------------------------------------------------------------------

--------------------------------------------------------------------------------
TOTAL                                                               $ 32,513.82
--------------------------------------------------------------------------------

--------------------------------------------------------------------------------
<PAGE>

                                  EXHIBIT "E"
                                  -----------

                              ESTOPPEL CERTIFICATE

LEASE:                     Lease Agreement between Wells Operating Partnership,
                           L.P., as Landlord, and Nissan Motor Acceptance
                           Corporation dated September __, 2001, as amended
                           _____________________

TENANT:                    Nissan Motor Acceptance Corporation, a California
                           corporation

RENT COMMENCEMENT DATE:    __________________________________________________

DEMISED PREMISES:          __________________________________________________

TO:  Wells Operating Partnership, L.P.
     6200 The Corners Parkway
     Suite 250
     Atlanta, Georgia  30092

Ladies and Gentlemen:

     The undersigned hereby certifies to you as follows:

     1.   The undersigned is the "Tenant" under the above-referenced Lease
covering the above-referenced Demised Premises.  A true, correct and complete
copy of the Lease (including all addenda, riders, amendments, modifications and
supplements thereto) is attached hereto as Exhibit A.
                                           ---------

     2.   The Lease constitutes the entire agreement between Landlord under the
Lease ("Landlord") and Tenant with respect to the Demised Premises, and the
Lease has not been canceled, modified, changed, altered or amended in any
respect except as set forth on Exhibit A.
                               ---------

     3.   The Rent Commencement Date under the Lease occurred on __________,
200__, and the term of the Lease will expire on __________, 20__.  Tenant has
accepted possession of the Premises and is the actual occupant in possession and
has not sublet, assigned or hypothecated all or any portion of or interest in
Tenant's leasehold interest.  All improvements to be constructed on the Demised
Premises by Landlord have been completed and accepted by Tenant and any Tenant
construction allowances have been paid in full.

     4.   As of the date of this Estoppel Certificate, there exists no breach or
default, nor state of facts which, with notice, the passage of time, or both,
would result in a breach or default on the part of either Tenant or Landlord.
To the best of Tenant's knowledge, no claim, controversy, dispute, quarrel or
disagreement exists between Tenant and Landlord.  Tenant has no offset against
the rental due under the Lease.
<PAGE>

     5.   Tenant is currently obligated to pay annual Base Rent of $__________,
in monthly installments of $__________ per month.  In addition, Tenant is
obligated to pay as additional rent, all "Taxes" as provided in Paragraph 7 of
the Lease.  Tenant has deposited a security deposit of $  None  .
                                                        --------

     6.   Tenant has no option, right of first offer or right of first refusal
to lease or occupy any other space within the property of which the Demised
Premises are a part.

     7.   Tenant's "Purchase Option" provided under Section 13 of Exhibit "C"
attached to the Lease has terminated and is no longer exercisable by Tenant.
Tenant has been granted the right to purchase the "Project" (as defined in the
Lease) pursuant to Exhibit "F" attached to the Lease.  Except as provided in
Exhibit "F" attached to the Lease, Tenant has no option or preferential right to
purchase all or part of the Demised Premises (or the real property of which the
Demised Premises are a part) nor any right or interest with respect to the
Demised Premises other than as Tenant under the Lease.

     8.   Tenant has fully paid rent and other sums due Landlord through the
date hereof, and Tenant has not paid rent more than thirty (30) days in advance.
Tenant has made no agreement with Landlord or any agent, representative or
employee of Landlord concerning free rent, partial rent, rebate of rental
payments or any other type of rental or other concession except as expressly set
forth in the Lease.

     9.   There has not been filed by or against Tenant a petition in
bankruptcy, voluntary or otherwise, any assignment for benefit of creditors, any
petition seeking reorganization or arrangement under the bankruptcy laws of the
United States, or any state thereof, or any other action brought under said
bankruptcy laws with respect to Tenant.

     10.  All insurance required under the Lease to be obtained and maintained
by Tenant has been provided by Tenant, and all premiums due have been timely
paid.

     11.  To the best of Tenant's knowledge, there are no leasing commissions
owed with respect to the Lease.

     This Certificate may be relied on by Landlord and any other party who
acquires an interest in the Demised Premises in connection with any purchase, or
any person or entity which may provide financing with respect to the Demised
Premises.

                                      -2-
<PAGE>

     Dated this _____ day of __________, 200__.

                              TENANT:

                              NISSAN MOTOR ACCEPTANCE
                              CORPORATION, a California corporation

                              By:________________________________________

                              Name:______________________________________

                              Title:_____________________________________

                                      -3-
<PAGE>

                                  EXHIBIT "F"
                                  -----------

                          TOTAL PROJECT COSTS DEFINED

     The term "Total Project Costs" shall mean and include all costs and
expenses incurred by Owner in the acquisition of the Land, the designing,
engineering, planning, development, construction, installation and completion of
the Site Improvements, the Building and the Tenant Improvements, the negotiation
and documentation of this Agreement, the Nissan Lease, the Architect's
Agreement, the Construction Agreement, and the agreements with the other Owner
Consultants, and the financing of all of the foregoing, including, without
limitation, the following:

          (a)  the cost of acquiring the Land, including, without limitation,
     the purchase price thereof and any commissions, recording costs, transfer
     taxes, title examination charges, title insurance premiums, survey costs,
     and costs for environmental and geotechnical studies or reports;

          (b)  the cost of engineering, architectural, planning, surveying,
     accounting and other professional fees and expenses;

          (c)  the cost of developing, constructing and installing the Site
     Improvements, the Building and the Tenant Improvements;

          (d)  allowance amounts paid to Nissan or incurred by Owner under the
     Nissan Lease;

          (e)  any costs or damages paid to Nissan under the Nissan Lease as a
     result of the failure of the Project to be completed on or before any
     milestone dates set forth in the Nissan Lease;

          (f)  the Development Fee, Leasing Fee, and reimbursable expenses paid
     to Developer;

          (g)  the cost of environmental remediation to the extent necessary;

          (h)  the cost of insurance of all types maintained prior to the
     Completion Date, including all-risk insurance (in builder's risk form
     during construction) and all appropriate endorsements, rent loss insurance,
     commercial general liability insurance, and workers' compensation
     insurance;

          (i)  attorney's fees incurred in acquiring the Land, negotiating and
     documenting this Agreement, the Nissan Lease, the Architect's Agreement,
     the Construction Agreement, and the agreement with the other Owner
     Consultants, and developing, constructing and installing the Site
     Improvements, Building and Tenant Improvements;
<PAGE>

          (j)  leasing commissions incurred by Owner in connection with the
     Nissan Lease, except that the commission amount payable to any affiliate of
     Owner shall be limited as hereinafter provided;

          (k)  capitalized ad valorem taxes and assessments accruing for the
     period from the date of acquisition of the Land through the date preceding
     the Completion Date;

          (l)  utility installation and tap fees, permit fees, and impact fees;

          (m)  the cost of utilities incurred prior to the Completion Date;

          (n)  the cost of payment and performance bonds;

          (o)  the cost of an as-built survey of the Project obtained after
     substantial completion of the Project;

          (p)  the cost of testing and inspections;

          (q)  financing costs, fees and expenses (including, without
     limitation, commitment fees, loan origination fees, attorney's fees,
     appraisal fees, taxes, title insurance premiums, documentary taxes,
     recording costs, and lender inspection fees) incurred in connection with
     the acquisition and construction loan obtained by Owner; and

          (r)  the actual interest accrued under the acquisition and
     construction loan, if any, obtained by Owner with respect to the Project
     through the date preceding the Rent Commencement Date under the Nissan
     Lease (regardless of whether Nissan is actually paying Base Rent or
     effectuating a credit against Base Rent pursuant to Paragraphs 2 and/or 7
     of Exhibit "C" attached to the Nissan Lease or pursuant to Exhibit "D"
     attached to the Nissan Lease), plus the amount of imputed interest that
     would accrue on all costs and expenses comprising Total Project Costs
     (other than interest as provided in this item (r)) incurred by Owner and
     not funded under the acquisition and construction loan obtained by Owner,
     calculated from the date Owner incurs such costs and expenses through the
     date preceding the Rent Commencement Date under the Nissan Lease
     (regardless of whether Nissan is actually paying Base Rent or effectuating
     a credit against Base Rent pursuant to Paragraphs 2 and/or 7 of Exhibit "C"
     attached to the Nissan Lease or pursuant to Exhibit "D" attached to the
     Nissan Lease) at the rate equal to the rate of interest charged to Owner
     under Owner's existing line of credit from Bank of America, N.A. (which
     interest rate is the 30-day adjusted LIBOR rate plus 200 basis points).

In determining the Total Project Costs, there shall be deducted (i) any
                                                       --------
contribution made to such Total Project Costs by Nissan (whether through direct
payment to the Owner or an increase in Base Rent payable to the Owner as
Landlord under the Nissan Lease and not taken into account in calculating the
Capitalized Rent Amount), and (ii) any proceeds of casualty insurance paid to
the Owner (or to the Owner's lender).  Notwithstanding anything in this Exhibit
                                                                        -------
"F" to the contrary, (i) the leasing commission amounts payable in connection
---
with the Nissan Lease

                                      -2-
<PAGE>

(exclusive of the leasing commission payable to The Staubach Company and the
Leasing Fee) and the commitment fee and/or origination fee amounts payable in
connection with the acquisition and construction loan which are included in the
Total Project Costs shall not exceed, in the aggregate, the sum of $828,600.00.

                                      -3-
<PAGE>

                              EXHIBIT "G" - PART 1
                              --------------------

                     DEVELOPER'S FINAL, UNCONDITIONAL LIEN
                                                      ----
                     WAIVER AND RELEASE UPON FINAL PAYMENT
          (To be provided by Developer at the time of final payment)

STATE OF TEXAS
COUNTY OF DALLAS

     The undersigned, Champion Partners, Ltd. ("Developer"), has been engaged
under an agreement with Wells Operating Partnership, L.P. ("Owner") to furnish
certain materials, equipment, services and/or labor for the construction of
improvements known as the Nissan Office Project, together with all improvements
and appurtenances attendant thereto, which is owned by Owner and is located in
Dallas County, Texas, and more particularly described as follows:______________
_______________________________________________________________________________
_______________________________________________________________________________
(DESCRIBE THE PROPERTY UPON WHICH THE IMPROVEMENTS WERE MADE BY USING EITHER A
METES AND BOUNDS DESCRIPTION, THE LAND LOT, DISTRICT, BLOCK AND LOT NUMBER, OR
STREET ADDRESS OF THE PROJECT).

     The Developer waives and releases any and all liens or claims of liens or
any right against any labor and/or material bond it has upon the foregoing
described property.

     The Developer further represents that all of its obligations, legal,
equitable or otherwise, relating to or arising out of its work on the Project
have been fully satisfied, including, but not limited to, obligations relating
to:

     .    Subconsultants, employees, laborers, materialmen and subcontractors
          employed by the Developer;
     .    Labor, materials, equipment and supplies furnished by others to the
          Developer; and
     .    Sales and use taxes, social security taxes, income tax withholding,
          unemployment insurance, privilege taxes, license fees, and any other
          taxes and obligations imposed by governmental authorities.

     Developer agrees that this waiver and release form is in compliance with
all applicable Texas laws and regulations.

NOTICE: THIS DOCUMENT WAIVES RIGHTS UNCONDITIONALLY AND STATES THAT YOU HAVE
BEEN PAID FOR GIVING UP THOSE RIGHTS. THIS DOCUMENT IS ENFORCEABLE AGAINST YOU
IF YOU SIGN IT, EVEN IF YOU HAVE NOT BEEN PAID

                                 FOR DEVELOPER:

Applicable to application for payment(s) No.       All     *
                                             --------------
*If all, print "all."
Signed:____________________________________________________
By:________________________________________________________
Title:_____________________________________________________
Date:______________________________________________________
<PAGE>

STATE OF TEXAS      (S)
                    (S)
COUNTY OF DALLAS    (S)

     This instrument was ACKNOWLEDGED before me on _______________, 200__, by
________________________________________, the ______________________________ of
CHAMPION INTERESTS, INC., a Texas corporation, on behalf of CHAMPION HOLDINGS,
LTD., a Texas limited partnership on behalf of said partnership as the General
Partner of CHAMPION PARTNERS, LTD., a Texas limited partnership, on behalf of
said partnership.

[S E A L]                     ___________________________________________
                              Notary Public - State of Texas

My Commission Expires:

________________________      ___________________________________________
                              Printed Name of Notary Public

                                      -2-
<PAGE>

                                  EXHIBIT "H"
                                  -----------

                     ACTIONS OF DEVELOPER RATIFIED BY OWNER
<PAGE>

                                  EXHIBIT "H"

                    ACTIONS OF DEVELOPER RATIFIED BY OWNER

1.   The Development Budget has been approved per Section 4.2.1.

2.   The Architect Agreement has been approved for signature per Section 4.2.2.

3.   The Architect has been approved per Section 4.2.3.

4.   The Project Design Criteria has been approved per Section 4.2.4.

5.   Preliminary Boundary Surveys have been approved per Section 4.2.6.

6.   Preliminary site Plans have been approved per Section 4.2.7.

7.   Preliminary Drawings and specifications have been approved per Section
     4.2.8.

8.   The Phase 1 Environmental Reports have been approved per Section 4.2.9.

9.   The Geotechnical/Soils Reports have been approved per Section 4.2.10.

10.  Section 4.3.3 regarding Standard Interior Finishes is Not Applicable.

11.  Section 4.3.6 regarding Owner Consultant Schedules is Not Applicable.

12.  The General Contractor has been approved per Section 4.3.11 and Section
     4.3.13.

13.  The Construction Agreement has been approved for signature per Section
     4.3.12.

14.  Builder's Risk Insurance will be provided by the General Contractor per
     Section 4.5.14.

<PAGE>

                                  EXHIBIT "I"
                                  -----------

                    NISSAN LEASE TAKEOVER AND LAND PURCHASE

     Pursuant to a Developer Agreement and an Option Agreement between Nissan
and Developer (copies of which agreements have been provided to Owner),
Developer has agreed to incur certain lease takeover obligations and land
purchase obligations as described in the Champion Memorandum dated July 30, 2001
(the "Memorandum").  For purposes of this Exhibit "I", the term "Total Lease
                                          -----------
Takeover Net Costs" shall be defined as the aggregate net costs, if any,
actually incurred by Developer with respect to the lease takeover obligations
and the land purchase and eventual resale as set forth in the Memorandum.  In
the event no net costs are so incurred or in the event a net benefit is actually
achieved, then the Total Lease Takeover Net Costs shall be deemed to be zero.

     If any unfunded amounts remain in the Development Budget line items for
"Landlord Contingency" and "Construction Period and Land Interest" upon the
Completion Date and the final calculation of Total Project Costs, then such
aggregate unfunded amounts (the "Reserve Account") shall be treated in the
following order of priority:

     (A)  First, there shall be deducted from the Reserve Account up to $100,000
          of any unfunded amount remaining in the Development Budget line item
          for "Construction Period and Land Interest", and the amount so
          deducted shall be retained by Owner;

     (B)  Second, Developer shall be entitled to receive that amount of the
          remaining balance, if any, of the Reserve Account upon the Completion
          Date and the final calculation of Total Project Costs such that the
          amount of the Tenant Occupancy Fee payable to Developer equals One
          Million and No/100 Dollars ($1,000,000.00);

     (C)  Next, for a period of up to eighteen (18) months following the
          Completion Date and the final calculation of Total Project Costs,
          Developer shall have the right to use the remaining balance, if any,
          of the Reserve Account (thereby increasing the Tenant Occupancy Fee)
          up to that amount which brings the Total Lease Takeover Net Costs to a
          zero balance; and

     (D)  Thereafter, upon the earlier of (i) the date eighteen (18) months
          following the Completion Date and the final calculation of Total
          Project Costs, or (ii) the date upon which the Total Lease Takeover
          Net Costs have been brought to a zero balance, fifty percent (50%) of
          the remaining portion, if any, of the Reserve Account shall be
          promptly funded to Developer as the final payment of its Tenant
          Occupancy Fee, with the other fifty percent (50%) being retained by
          Owner.

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00030-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00030-of-00352.parquet"}]]