Document:

<PAGE>

                   AMENDMENT #1 TO SATELLITE SERVICE AGREEMENT

       THIS AMENDMENT #1 ("Amendment #1") to the Satellite Service Agreement
effective as of March 21, 2003 (the "Original Agreement"), between SES Americom,
Inc., as agent for SES Americom California, Inc. (for the period prior to the
In-Service Date) and SES Americom Colorado, Inc. (for the period on and after
the In-Service Date), on the one hand, and EchoStar Satellite Corporation
("Customer") and EchoStar Communications Corporation (solely as to the
obligation set forth in Section 3.C of the Agreement), on the other hand, is
made effective as of July 10, 2003 (the "Amendment #1 Effective Date"). All
references to "SES Americom" herein shall include SES Americom California, Inc.,
SES Americom Colorado, Inc., and SES Americom, Inc. as agent for each. Defined
terms used in this Agreement have the meanings specified herein or in the
Original Agreement. The Original Agreement as amended by this Amendment #1 is
referred to as the "Agreement".

       SES Americom and Customer agree to amend the Original Agreement in
accordance with the terms and conditions set forth below.

         (1) *** Within thirty (30) days after the Amendment #1 Effective Date,
         the parties shall enter into a service agreement (the "AMC-14
         Agreement") for the *** Satellite on the terms and conditions described
         ***

(3) Miscellaneous Modifications. *** Section 10.A of the Original Agreement is
amended by renumbering Subsection (2) as Subsection (3) and inserting the
following after Subsection (1): "(2) as to Customer, relates to or affects its
ability to achieve the In-Service Date of the EchoStar *** Satellite."

(4) New Section 2.N. The Original Agreement is amended to add the following as a
new Section 2.N:

           ***

(5) Definitions. The following definitions are added to Article 11:

       ***

(6) Conditions. All of the rights and obligations of the parties set forth in
this Amendment #1 are conditioned on the execution and implementation of the
AMC-14 Agreement, failing which this Amendment #1 shall be void ab initio and
the Original Agreement shall remain in full force and effect in accordance with
its terms and conditions.

(7) General. Except as expressly modified herein, the Original Agreement shall
remain in full force and effect in accordance with its terms and conditions.

***Certain confidential portions of this exhibit were omitted by means of
redacting a portion of the text. Copies of the exhibit containing the redacted
portions have been filed separately with the Securities and Exchange Commission
subject to a request for confidential treatment pursuant to Rule 24b-2 under the
Securities Exchange Act.

                                       -1-
<PAGE>

       This AMENDMENT #1 contains the complete and exclusive understanding of
the parties with respect to the subject matter hereof and supersedes all prior
negotiations and agreements between the parties with respect thereto.

ECHOSTAR SATELLITE CORPORATION              SES AMERICOM, INC., as agent for
                                            SES AMERICOM CALIFORNIA, INC. and
                                            SES AMERICOM COLORADO, INC.

By:                                         By:
    -----------------------------------         --------------------------------
(Signature)                                          (Signature)

Name:                                       Name:
      ---------------------------------           ------------------------------
(Typed or Printed Name)                              (Typed or Printed Name)

Title:                                      Title:
       --------------------------------            -----------------------------

ECHOSTAR COMMUNICATIONS CORPORATION,
solely as to the obligation set forth
in Section 3.C of the Agreement

By:
    -----------------------------------
(Signature)

Name:
      ---------------------------------
(Typed or Printed Name)

Title:
       --------------------------------

***Certain confidential portions of this exhibit were omitted by means of
redacting a portion of the text. Copies of the exhibit containing the redacted
portions have been filed separately with the Securities and Exchange Commission
subject to a request for confidential treatment pursuant to Rule 24b-2 under the
Securities Exchange Act.

                                       -2-<PAGE>
                                                                  Execution Copy

                     SATELLITE SERVICE AGREEMENT FOR AMC-14

       THIS AGREEMENT between SES Americom, Inc., as agent for SES Americom
California, Inc. (for the period prior to the In-Service Date) and SES Americom
Colorado, Inc. (for the period on and after the In-Service Date), on the one
hand, and EchoStar Satellite Corporation ("Customer") and EchoStar
Communications Corporation (solely as to the obligation set forth in Section 3.C
of this Agreement), on the other hand, is made effective as of August 13, 2003
(the "Effective Date"). All references to "SES Americom" herein shall include
SES Americom California, Inc., SES Americom Colorado, Inc., and SES Americom,
Inc. as agent for each. Defined terms used in this Agreement have the meanings
specified herein.

                           ARTICLE 1. SERVICE PROVIDED

1.A. SCOPE.***

       SES Americom will enter into a contract (the "Construction Contract")
with Vendor for the construction of one *** satellite designated as the "AMC-14
Satellite", and will enter into a Launch Service Agreement for the launch of the
AMC-14 Satellite. SES Americom will provide to Customer, and Customer will pay
the applicable MRC for, and be entitled to utilize solely for the Intended Use,
the entire communications capacity (including all spare capacity) on the
Satellite in accordance with this Agreement (the "Service"). ***

       The Service will be provided in accordance with the terms and conditions
set forth in this Agreement, including Attachments A - D (as listed below),
which are hereby incorporated by reference in their entirety (collectively, the
"Agreement"). In the event of any conflict or inconsistency between the terms
and conditions set forth in the body of this Agreement and the terms and
conditions set forth in any Attachment hereto, then terms and conditions set
forth in the body of this Agreement shall control.

              Attachment A - Technical Performance Specifications
              Attachment B - ***
              Attachment C - ***
              Attachment D - ***

       Customer may use the Transponders for the transmission of digital
services, and for the transmission of analog services, but only to the extent
that all services are consistent with the then-current licenses and coordination
agreements for the applicable orbital location. SES Americom shall have no
obligation to modify existing licenses or coordination agreements or enter into
new coordination agreements to allow analog services.

1.B. TERMS RELATED TO CONSTRUCTION CONTRACT, LAUNCH SERVICE AGREEMENT, AND
INSURANCE.

1.B(1) SES Americom and Customer shall collaborate in good faith toward reaching
agreements on the technical performance criteria for the Service on the AMC-14
Satellite (the "Technical Performance Specifications") and other requirements
for, and toward the successful construction, insurance and launch of, the AMC-14
Satellite, *** Upon reaching agreement on the Technical Performance
Specifications for the AMC-14 Satellite in accordance with this Subsection
1.B(1), the parties shall mutually agree upon the necessary modifications to (x)
Attachment B ***, and (y) ***

       Subject to the parties' respective rights and obligations set forth in
the immediately preceding paragraph, the parties will use reasonable commercial
efforts to execute the Construction Contract and complete the Technical
Performance Specifications in accordance with the steps outlined in this
paragraph, with a goal toward executing the Construction Contract and completing
the Technical Performance Specifications no later than *** Upon completion, the
Technical Performance Specifications shall be attached hereto as Attachment A,
and shall be deemed to be incorporated by reference in their entirety. ***

***Certain confidential portions of this exhibit were omitted by means of
redacting a portion of the text. Copies of the exhibit containing the redacted
portions have been filed separately with the Securities and Exchange Commission
subject to a request for confidential treatment pursuant to Rule 24b-2 under the
Securities Exchange Act.

                                        1

<PAGE>
                                                                  Execution Copy

1.B(2) SES Americom agrees to collaborate with and include Customer in all
significant decisions related to the Construction Contract, and to obtain
Customer's prior approval (which approval may be withheld in Customer's sole and
absolute discretion) prior to making any changes to the Technical Performance
Specifications, *** Subject to any applicable ITAR restrictions and Vendor's
standard security procedure requirements, Customer shall be permitted to
participate in and be present at: (a) reviews of each of Vendor's milestone
events leading up to launch of the Satellite; (b) Vendor's "Final Integration
and Test," "Pre-ship Review" and "Launch and In-Orbit Testing Sessions" (or
similar events if described differently in the Construction Contract); and (c)
informal Project Manager meetings and informal project level technical review
meetings. Participation by Customer as contemplated herein shall include
attendance by Customer employees and U.S. citizen representatives at such events
and meetings, consultation with Customer on engineering decisions that affect
the Satellite's performance (including the ability to meet the applicable
Technical Performance Specifications) and the review of relevant reports and
test results. When available to SES Americom and upon completion of any
necessary ITAR reviews and redactions, if applicable, SES Americom shall
distribute all design review documents to Customer. SES Americom shall also
instruct Vendor to make available to Customer employees and Customer's U.S.
citizen representatives access to all technical documents under the Construction
Contract, including without limitation the spacecraft performance specification,
subject to any applicable ITAR reviews and redactions. With reasonable prior
notice, SES Americom shall allow Customer, in the presence of SES Americom and
Vendor, to view program hardware in progress in accordance with Vendor's access
policies and procedures. Subject to any confidentiality restrictions set forth
in the Construction Contract, SES Americom shall afford Customer and Customer's
U.S. citizen representatives access, while accompanied by SES Americom, to all
work, including without limitation technical data and information, test data,
drawings, documentation, tooling, and manufacturing processes, testing and
hardware in progress, being performed at Vendor's facilities pursuant to the
Construction Contract at all times during the period of Construction Contract
performance, provided that such access does not unreasonably interfere with such
work or any other work. SES Americom shall afford Customer and Customer's U.S.
citizen representatives access, while accompanied by SES Americom, to work being
performed pursuant to the Construction Contract in Vendor's subcontractors'
facilities to the extent Vendor obtains such access, subject to the right of
Vendor and SES Americom to accompany Customer and Customer's U.S. citizen
representatives on any such visit and subject further to the execution by
Customer and Customer's U.S. citizen representatives of non-disclosure or
similar agreements as may be required by said subcontractors. SES Americom shall
use its reasonable commercial efforts to obtain Customer and Customer's U.S.
citizen representatives access, while accompanied by SES Americom, to the work
being performed pursuant to the Construction Contract in Vendor's
subcontractors' facilities. With respect to any access, documents or other
information that Vendor or SES Americom is obligated to provide to Customer's
U.S. citizen representatives under this Agreement, Customer shall be fully
responsible for, and shall indemnify and hold harmless SES Americom for any
losses, fines, penalties or liabilities arising from, any violation by Customer
or any of Customer's U.S. citizen representatives of any ITAR restrictions in
connection with access, documents or information so provided.

1.B(3) In the event that Customer requests a modification of any *** then SES
Americom will negotiate in good faith and in accordance with SES Americom's
duties and obligations under Subsection 3.A(11) with Vendor to implement such
modification. Customer acknowledges that any requested modification of the
Satellite would be subject to the change procedures set forth in the
Construction Contract and, to the extent such modification results in an
increase or decrease in price (including an increase or decrease in Incremental
Costs) or a change to the milestone schedule under the Construction Contract,
such increase or decrease in price (including an increase or decrease in
Incremental Costs) and/or the impact of such change to the milestone schedule
shall be passed through to Customer in the manner provided below. Customer
further acknowledges that any such modification may also require additional
approvals or authorizations from the FCC, which SES Americom shall use its
reasonable commercial efforts to obtain. The parties agree that the increase or
decrease in the Satellite Investment as a result of such a modification
requested by Customer will be reflected in the calculation of the MRC and that
the planned In-Service Date will be adjusted to reflect the change to the
milestone schedule in the Construction Contract.

***Certain confidential portions of this exhibit were omitted by means of
redacting a portion of the text. Copies of the exhibit containing the redacted
portions have been filed separately with the Securities and Exchange Commission
subject to a request for confidential treatment pursuant to Rule 24b-2 under the
Securities Exchange Act.

                                       2
<PAGE>
                                                                  Execution Copy

The parties agree to negotiate, in advance and in good faith, regarding any
other changes to this Agreement, if any, reasonably related to such
modifications, prior to implementing any such modifications. *** In the event
that, notwithstanding good faith negotiations, the parties are unable to agree
to the other changes, if any, to this Agreement reasonably related to such
modifications, no modifications to the Satellite will be made.

1.B(4) SES Americom agrees to collaborate with and include Customer in all
significant decisions related to the matters surrounding the Launch Service
Agreement, although the parties agree that SES Americom will make the final
decisions under the Launch Service Agreement (provided such decisions are
consistent with SES Americom's obligations under this Agreement and do not
adversely impact the rights of Customer under this Agreement). Subject to any
applicable ITAR restrictions, Customer employees and Customer's U.S. citizen
representatives shall be permitted to participate in reviews of each of the
launch service provider's milestone events with respect to launch of the
Satellite. Customer and Customer's guests may at Customer's expense attend the
launch of the Satellite.

1.B(5) To the extent that a failure by SES Americom to make payments in
accordance with the terms of the Construction Contract or the Launch Service
Agreement is the direct cause of a delay in the In-Service Date of the
Satellite, then in addition to any rights and remedies that Customer may have in
this Agreement, SES Americom will pay Customer ***

***

1.C. SERVICE TERM. The term for Service (the "Service Term") on any Satellite
*** shall commence on the In-Service Date for that Satellite, and, except as
otherwise provided herein, shall expire on the earlier of (1) ten years after
such In-Service Date (the "Initial Term"), or (2) the date that Satellite
becomes a Failed Satellite. The Service Term on any Satellite *** that is not a
Failed Satellite may be extended at Customer's sole option for successive
one-year periods (or a portion thereof in the case of the final extension) until
the Satellite reaches its End-of-Life (each an "Extended Term"), upon written
notice to SES Americom provided at least 180 days prior to the end of the
Initial Term and/or the then current Extended Term, and provided that, at the
time of each such extension, Customer is in full compliance with all of its
obligations under this Agreement.

1.D. SERVICE PRIORITIES. In the event of a Partial Loss, SES Americom shall
immediately initiate all commercially and technically reasonable measures,
consistent with protecting the Satellite and all services provided thereon, to
restore the Service as quickly as possible. Restoration shall be effected by
utilizing any available spare equipment on the Satellite to restore the Service
and/or the Transponder. If access to spare equipment on the Satellite is
required for more than one Transponder as a result of a single event or
simultaneous events, Customer will determine the preferred use of the spare
equipment, provided that Customer's decision does not adversely impact the
Satellite.

1.E. NOTICES. All notices regarding technical or operational matters requiring
immediate attention will be given by telephone to the telephone number set forth
below for Customer and the telephone number set forth in the User's Guide for
SES Americom and shall be followed by written notification. Any notice required
or permitted to be given hereunder shall be in writing and shall be sent by
facsimile transmission, or by first class certified mail, postage prepaid, or by
overnight courier service, charges prepaid, to the party notified, addressed to
such party at the address set forth below, or sent by facsimile to the fax
number set forth below, or such other address or fax number as such party may
have substituted by written notice to the other party. The sending of such
notice with confirmation of receipt thereof (in the case of facsimile
transmission) or receipt of such notice (in the case of delivery by mail or by
overnight courier service) shall constitute the giving thereof.

***Certain confidential portions of this exhibit were omitted by means of
redacting a portion of the text. Copies of the exhibit containing the redacted
portions have been filed separately with the Securities and Exchange Commission
subject to a request for confidential treatment pursuant to Rule 24b-2 under the
Securities Exchange Act.

                                       3
<PAGE>
                                                                  Execution Copy

         IF TO BE GIVEN TO CUSTOMER:        IF TO BE GIVEN TO SES AMERICOM:
         Attn: ***                          Attn: ***
         Vice President, Space Programs     General Counsel
         and Operations
         EchoStar Satellite Corporation     SES Americom, Inc.
         5701 South Santa Fe Drive          Four Research Way
         Littleton, CO  80120               Princeton, NJ  08540
         Fax #: ***                         Fax #: ***

         cc:  David K. Moskowitz, Esq.
         Senior Vice President &
         General Counsel
         (same address and fax number)

         ***

         ARTICLE 2. PAYMENTS AND OTHER CONSIDERATIONS/ FUTURE SATELLITES

2.A. ***

2.A(1) ***

2.B. MONTHLY RECURRING SERVICE CHARGE. Commencing on the In-Service Date, and
for the duration of the Service Term (including any Extended Terms) Customer
will pay to SES Americom for the Service a monthly recurring service charge (the
"MRC") with respect to the AMC-14 Satellite determined as of the In-Service Date
***

2.C. MRC ADJUSTMENTS/REFUNDS.

2.C(1) In the event of a Partial Loss (but not a Satellite Failure), Customer
shall be entitled to a refund of any MRC already paid, and a reduction of the
MRC to be paid, in either case applicable to the period of such Partial Loss
until either (a) such Partial Loss is restored through the use of spare
equipment on the Satellite, or (b) the Service Term ends, in an amount
calculated in accordance with the provisions in Attachment B hereto *** In the
event of a Satellite Failure for any reason whatsoever, Customer's obligation to
pay the MRC due for the period after the Satellite Failure shall automatically
terminate as of the date of the Satellite Failure, *** SES Americom will refund
to Customer any MRC paid for periods subsequent to the date of a Satellite
Failure, including the period between and including the date of the Satellite
Failure and the date upon which it is determined that a Satellite Failure has
occurred.

***

2.E. BILLING AND PAYMENT. On the In-Service Date, initial invoices for the MRC
will be issued for the first two months (or first partial month and subsequent
month, as applicable) of Service, and are payable within 15 Business Days after
the In-Service Date. Invoices for the MRC will thereafter be issued monthly
thirty (30) days in advance of the month in which Service is to be provided and
are payable on the first day of such month by wire transfer or Customer check as
per the remittance instructions on the respective monthly invoice (or, in the
event Customer has not received such invoice, in accordance with SES Americom's
most recent remittance instructions). Invoices for partial months will be
prorated on the basis of a 30-day month. On payments not received by the due
date, SES Americom will assess a late payment charge of the lesser of *** A
failure or delay by SES Americom to send an invoice will not relieve Customer
either of its obligation to pay on a timely basis for Service or of its
obligation to pay late payment charges in the event of late payment.

2.F. TAXES AND OTHER CHARGES. The MRC shall be exclusive of taxes, duties and
other fees or charges levied by governmental authorities on the Service or the
facilities used to provide the Service to Customer. Customer will pay directly
or reimburse SES Americom for all such taxes, duties and other fees or charges.
SES Americom represents that, as of the date hereof, it has no actual knowledge
of any taxes, duties or

***Certain confidential portions of this exhibit were omitted by means of
redacting a portion of the text. Copies of the exhibit containing the redacted
portions have been filed separately with the Securities and Exchange Commission
subject to a request for confidential treatment pursuant to Rule 24b-2 under the
Securities Exchange Act.

                                       4
<PAGE>
                                                                  Execution Copy

other fees or charges (1) which would be levied on SES Americom by any
governmental authorities, (2) which would apply to the Service at the Orbital
Location or the Alternate Orbital Location or the facilities used to provide the
Service at the Orbital Location or the Alternate Orbital Location to Customer,
provided that the Service is used solely for its Intended Use, and (3) for which
SES Americom would seek reimbursement from Customer. Notwithstanding the
foregoing, in no event will Customer be liable for any taxes based upon or
measured by SES Americom's net income or property or employment taxes of SES
Americom or any license or permit fees imposed generally on SES Americom's use
of the Orbital Location or the Alternate Orbital Location, SES Americom's
operation of the Satellite or the facilities used to provide the Service.

2.G. TERMS APPLICABLE TO THE AMC-14 SATELLITE.

***

              ARTICLE 3. REPRESENTATIONS, WARRANTIES AND COVENANTS

3.A. SES AMERICOM'S REPRESENTATIONS, WARRANTIES AND COVENANTS. SES Americom
hereby represents, warrants and covenants to Customer as follows:

3.A(1) It is a corporation duly organized, validly existing and in good standing
under the laws of the State of Delaware. It is duly licensed or qualified to do
business as a foreign corporation in all jurisdictions where the failure to be
so qualified would materially adversely affect its ability to perform its
obligations hereunder. It has all requisite corporate power and authority to own
its properties and carry on its business as now conducted.

3.A(2) The execution, delivery and performance (as provided herein) by SES
Americom of this Agreement has been duly authorized by all requisite corporate
action and will not violate any applicable provisions of law or any order of any
court or any agency of government and will not conflict with or result in a
breach under (a) its Articles of Incorporation or By-Laws, or (b) any material
agreement to which SES Americom is a party or by which it is bound.

3.A(3) SES Americom has not retained or authorized anyone to represent it as a
broker or finder in connection with this Agreement.

3.A(4) In connection with SES Americom's performance under this Agreement, SES
Americom shall comply in all material respects with all applicable laws,
regulations, or orders of any governmental entity, including without limitation
the FCC.

3.A(5) SES Americom (a) has filed, and will diligently prosecute, application(s)
with the FCC to launch and operate the AMC-14 Satellite *** in geostationary
orbit at the Orbital Location and (b) agrees to use reasonable commercial
efforts to acquire and maintain all necessary governmental authorizations or
permissions to operate the Satellite (including without limitation providing DBS
Service) at the Orbital Location in a manner consistent with the Technical
Performance Specifications and its Intended Use. SES Americom will comply in all
material respects with all applicable FCC and other governmental and
intergovernmental orders and regulations regarding the licensing and operation
of the Satellite ***. SES Americom shall use all reasonable efforts to resist
any move of the Satellite from the Orbital Location. In the event that SES
Americom is required by order of the FCC to change the Orbital Location or
because of an FCC order or for any other reason (provided that such order or
such other reason is not caused solely by the acts or failures to act of
Customer in compliance with its representations, warranties or covenants under
this Agreement) does not have the right to operate the Satellite at the Orbital
Location for the benefit of Customer in accordance with this Agreement and for
its Intended Use, then, effective at the time the Service is terminated for the
foregoing reason, Customer shall be entitled to terminate this Agreement without
any further liability to SES Americom.

***Certain confidential portions of this exhibit were omitted by means of
redacting a portion of the text. Copies of the exhibit containing the redacted
portions have been filed separately with the Securities and Exchange Commission
subject to a request for confidential treatment pursuant to Rule 24b-2 under the
Securities Exchange Act.

                                       5
<PAGE>
                                                                  Execution Copy

3.A(6) *** .

3.A(7) SES Americom will use reasonable commercial efforts to enter into
coordination agreements necessary for operation of the Satellite at the Orbital
Location and the Alternate Orbital Location consistent with (a) SES Americom's
obligations in Subsections 2.K(1)(c) and 2.K(6)(c) of the AMC-15 Agreement, (b)
the Technical Performance Specifications, and (c) the Intended Use (the
"Coordination Agreements") and, once executed, will not amend such coordination
agreements in a way that would adversely impact Customer without Customer's
prior written consent.

3.A(8) In accordance with requests made and instructions given by Customer, SES
Americom shall use commercially reasonable efforts, at Customer's reasonable
expense, to support Customer's efforts in obtaining any site licenses, earth
station authorizations and other necessary FCC and other governmental
authorizations to communicate with the Satellite for the Intended Use, provided
that SES Americom shall have no duty or obligation whatsoever under this
Subsection (8) to act or refrain from acting in any way that would materially
adversely impact SES Americom.

3.A(9) ***

3.A(10) SES Americom's Program Management for the Satellite will apply the same
degree of care as is normally applied by SES Americom to satellite construction
efforts for the other satellites owned by SES Americom.

3.A(11) ***

3.A(12) SES Americom will not amend the Construction Contract in a way that
would adversely impact Customer or terminate the Construction Contract without
the express written concurrence of Customer, provided that Customer's
concurrence shall not be required if notice has been given of the termination of
this Agreement.

3.A(13) ***

3.B. CUSTOMER'S REPRESENTATIONS, WARRANTIES AND COVENANTS. Customer hereby
represents, warrants and covenants to SES Americom as follows:

3.B(1) It is a corporation duly organized, validly existing and in good standing
under the laws of Colorado. It is duly licensed or qualified to do business as a
foreign corporation in all jurisdictions where the failure to be so qualified
would materially adversely affect its ability to perform its obligations
hereunder. It has all requisite corporate power and authority to own its
properties and carry on its business as now conducted.

3.B(2) The execution, delivery and performance (as provided herein) by Customer
of this Agreement has been duly authorized by all requisite corporate action and
will not violate any applicable provisions of law or any order of any court or
agency of government and will not conflict with or result in a breach under (a)
its Articles of Incorporation or By-Laws, or (b) any material agreement to which
Customer is a party or by which it is bound.

3.B(3) Customer has not employed or authorized anyone to represent it as a
broker or finder in connection with this Agreement.

3.B(4) In connection with Customer's performance under this Agreement, Customer
shall comply in all material respects with all applicable laws, regulations, or
orders of any governmental entity, including without limitation those governing
content of transmissions and all FCC license requirements.

***Certain confidential portions of this exhibit were omitted by means of
redacting a portion of the text. Copies of the exhibit containing the redacted
portions have been filed separately with the Securities and Exchange Commission
subject to a request for confidential treatment pursuant to Rule 24b-2 under the
Securities Exchange Act.

                                       6
<PAGE>
                                                                  Execution Copy

3.B(5) Customer will properly illuminate and will use commercially reasonable
efforts to cause third parties that Customer authorizes to use the Service to
properly illuminate the Transponders.

3.B(6) Upon a written request therefor by SES Americom, but in no event more
often than once per calendar year, Customer shall provide to SES Americom a
certification duly executed by an officer of Customer, to the effect that
Customer's net long term assets (as defined under GAAP) reflected on Customer's
balance sheet for the immediately preceding calendar quarter exceed or are equal
to $1.2 Billion.

3.B(7) ***

3.C. ECHOSTAR COMMUNICATIONS CORPORATION REPRESENTATIONS, WARRANTIES AND
COVENANTS.

3.C(1) EchoStar Communications Corporation hereby represents, warrants, and
covenants, solely with respect to the obligation set forth in Subsection (2)
below, as follows:

              (a) It is a corporation duly organized, validly existing and in
good standing under the laws of Nevada. It is duly licensed or qualified to do
business as a foreign corporation in all jurisdictions where the failure to be
so qualified would materially adversely affect its ability to perform its
obligations hereunder. It has all requisite corporate power and authority to own
its properties and carry on its business as now conducted.

              (b) The execution, delivery and performance (as provided herein)
by EchoStar Communications Corporation of the obligation set forth in Subsection
(2) below has been duly authorized by all requisite corporate action and will
not violate any applicable provisions of law or any order of any court or agency
of government and will not conflict with or result in a breach under (a) its
Articles of Incorporation or By-Laws, or (b) any material agreement to which
EchoStar Communications Corporation is a party or by which it is bound.

3.C(2) In the event that Customer's net long term assets (as defined under GAAP)
reflected on Customer's balance sheet for any calendar quarter after the
Effective Date are less than $1.2 Billion, then EchoStar Communications
Corporation, or any successor entity thereto that is the ultimate parent of
Customer, shall become, effective at the end of such calendar quarter,
absolutely, irrevocably, unconditionally and continually obligated to SES
Americom to perform fully and timely all of the payment and other obligations
and covenants of Customer hereunder.

                       ARTICLE 4. SERVICE RESPONSIBILITIES

4.A. LAWS AND REGULATIONS GOVERNING SERVICE. Construction, launch, location and
operation of the Satellite, SES Americom's satellite system and SES Americom's
performance of all obligations pursuant to this Agreement are subject to all
applicable laws and regulations, including without limitation ITAR, as amended,
the Communications Act of 1934, as amended, the rules and regulations of the
FCC, and coordination agreements with other operators and administrations.

4.B. USE CONDITIONS.

4.B(1) Customer will use the Service in accordance with (a) all applicable laws
and regulations and (b) the conditions of use to be contained in a Commercial
Operations Systems User's Guide to be agreed to by the parties (the "User's
Guide"). Customer will not use the Service for any unlawful purpose, including
violation of laws governing the content of material transmitted using the
Service. If Customer's non-compliance with the preceding two sentences causes or
threatens, or other circumstances arise from Customer's use of the Service which
cause or threaten, damage to the Satellite, or if Customer's use of Service may
reasonably result in the institution of criminal proceedings, or administrative
proceedings that

***Certain confidential portions of this exhibit were omitted by means of
redacting a portion of the text. Copies of the exhibit containing the redacted
portions have been filed separately with the Securities and Exchange Commission
subject to a request for confidential treatment pursuant to Rule 24b-2 under the
Securities Exchange Act.

                                       7
<PAGE>
                                                                  Execution Copy

may result in sanctions or other non-monetary remedies, against SES Americom,
SES Global SA, or any Affiliates of either entity, SES Americom may take actions
(including suspension and/or restriction of Service) it reasonably believes
necessary to ensure Customer's compliance with the User's Guide or SES
Americom's compliance with law. SES Americom will provide Customer with advance
notice as reasonably practicable prior to taking any such action; provided that
the foregoing shall not preclude SES Americom from taking prompt action to
preserve its interests. SES Americom will also provide continuous monitoring of
the Satellite in accordance with generally accepted industry standards.

4.B(2) Customer shall be responsible for the failure of third parties (e.g.,
subcontractors) who Customer utilizes in conjunction with the Service
("Customer's Designees") to meet the requirements of Subsection (1) above as if
such failures were actions of Customer.

***

                         ARTICLE 5. OPERATIONAL MATTERS

5.A. SERVICE ACCESS. Customer is responsible for providing, operating and
maintaining the equipment necessary to access the Satellite and Service. At no
additional cost to Customer, SES Americom shall be responsible for providing
telemetry, tracking and control ("TT&C") service for the Satellite, and shall
perform TT&C service on the same standards as applied by SES Americom to the
rest of its satellite fleet. Customer at its expense shall provide SES Americom
with any descrambling or decoding devices that may be required for signal
monitoring. At a mutually agreed time, and prior to Customer transmitting from
its earth station(s), Customer will demonstrate to SES Americom's designated
Technical Operations Center that its earth station(s) comply with the satellite
access specifications contained in the User's Guide.

5.B. ACTION TO PROTECT SATELLITE. SES Americom shall have sole and exclusive
control of operation of the Satellite. If circumstances occur which in SES
Americom's reasonable judgment pose a threat to the stable operation of the
Satellite, SES Americom shall have the right to take action it reasonably
believes necessary to protect the Satellite, including discontinuance or
suspension of operation of the Satellite or any Transponder, without any
liability to Customer, except as otherwise set forth in this Agreement, *** If
the discontinuance or suspension of operation is permanent, then, if the
discontinuance applies to the entire Satellite, it shall be treated as a
Satellite Failure for purposes of Section 2.C, and if the discontinuance applies
to particular Transponders, it shall be treated as a Partial Loss for purposes
of Section 2.C. SES Americom shall give Customer as much notice as practical
under the circumstances of any such discontinuance or suspension. If it becomes
necessary to discontinue or suspend service on one or more Transponders on the
Satellite, and operational circumstances allow SES Americom to select the
Transponder or Transponders to be discontinued or suspended, SES Americom will
consult with Customer and implement Customer's preferred course of action, such
consultation to take place prior to action by SES Americom unless more immediate
action is necessary.

5.C. CERTAIN OTHER OPERATIONAL MATTERS.

***

                           ARTICLE 6. INDEMNIFICATION

6.A. BY CUSTOMER. ***

6.B. BY SES AMERICOM ***

6.C. SURVIVAL. The provisions of this Article 6 shall survive expiration or
termination of this Agreement indefinitely.

             ARTICLE 7. WARRANTY DISCLAIMER; LIMITATION OF LIABILITY

***Certain confidential portions of this exhibit were omitted by means of
redacting a portion of the text. Copies of the exhibit containing the redacted
portions have been filed separately with the Securities and Exchange Commission
subject to a request for confidential treatment pursuant to Rule 24b-2 under the
Securities Exchange Act.

                                       8
<PAGE>
                                                                  Execution Copy

7.A. WARRANTY DISCLAIMER. ***

7.B. LIMITATION OF LIABILITY.

.................................................................................

7.C. SURVIVAL. The provisions of this Article 7 shall survive expiration or
termination of this Agreement indefinitely.

                  ARTICLE 8. CONFIDENTIALITY AND NONDISCLOSURE

8.A. CERTAIN INFORMATION REGARDING SERVICE. Except for disclosures required by a
court or governmental agency or to assignees permitted under Section 10.I, each
party hereby agrees not to disclose to third parties (without the prior written
consent of the other party) the material terms and conditions of this Agreement
(including but not limited to the prices, payment terms, schedules, protection
arrangements, and restoration provisions thereof), and all information provided
to Customer and SES Americom related to the design and performance
characteristics of the Satellite, and any subsystems or components thereof,
including the Transponders). Notwithstanding the foregoing, Customer (and not
SES Americom) may disclose to its third-party customers making use of the
Service, and SES Americom (and not Customer) may disclose to its third party
vendors and contractors providing services relating to the Satellite (including
but not limited to insurance and launch service providers), the Technical
Performance Specifications, the User's Guide, and the protection arrangements
and restoration provisions of the Service.

8.B. PROPRIETARY INFORMATION. To the extent that either party discloses to the
other any other information which it considers proprietary or is proprietary
information of a third party, in written or tangible form, said party shall
identify such information as proprietary when disclosing it to the other party
by marking it clearly and conspicuously as proprietary information. Any
proprietary disclosure to either party, if made orally, shall be identified as
proprietary information at the time of disclosure, if the disclosing party
wishes to keep such information proprietary under this Agreement. Any such
information disclosed under this Agreement shall be used by the recipient
thereof only in its performance under this Agreement.

       Neither party shall be liable for the inadvertent or accidental
disclosure of such information marked as proprietary, if such disclosure occurs
despite the exercising of the same degree of care as the receiving party
normally takes to preserve and safeguard its own proprietary information (but
not less than reasonable care) or if such information (1) is or becomes lawfully
available to the public from a source other than the receiving party before or
during the period of this Agreement, (2) is released in writing by the
disclosing party without restrictions, (3) is lawfully obtained by the receiving
party from a third party or parties without obligation of confidentiality, (4)
is lawfully known by the receiving party prior to such disclosure and is not
subject to any confidentiality obligations, or (5) is at any time lawfully
developed by the receiving party completely independently of any such disclosure
or disclosures from the disclosing party.

       In addition, neither party shall be liable for the disclosure of any
proprietary information which it receives under this Agreement pursuant to
judicial action or decree, or pursuant to any requirement of any Government or
any agency or department thereof, having jurisdiction over such party, provided
that in the reasonable opinion of counsel for such party such disclosure is
required, and provided further that such party, to the extent reasonably
practical, shall have given the other party notice prior to such disclosure.

       Customer and SES Americom agree to negotiate in good faith a three-party
non-disclosure agreement with Vendor for information to be disclosed related to
this Agreement.

8.C. SURVIVAL. The provisions of this Article 8 shall survive expiration or
termination of this Agreement indefinitely.

                             ARTICLE 9. TERMINATION

***Certain confidential portions of this exhibit were omitted by means of
redacting a portion of the text. Copies of the exhibit containing the redacted
portions have been filed separately with the Securities and Exchange Commission
subject to a request for confidential treatment pursuant to Rule 24b-2 under the
Securities Exchange Act.

                                       9
<PAGE>
                                                                  Execution Copy

9.A. TERMINATION FOR DEFAULT. In addition to any rights of termination provided
in other Articles of this Agreement, either party may terminate this Agreement
(a "Termination for Default") by giving the other party written notice thereof
in the event: (1) the other party materially breaches this Agreement (except for
a breach of Article 8) and fails to cure such breach within thirty (30) days
after receipt of written notice thereof (except that, if the breaching party
fails to pay amounts due hereunder, such cure period shall be reduced to twenty
(20) days for the second and subsequent failures in any one calendar year, and,
in lieu of termination, SES Americom may, in its sole discretion, suspend the
provision to Customer of the Service, with no liability to Customer); or (2) the
other party becomes insolvent or the subject of insolvency proceedings,
including without limitation if the other party is judicially declared insolvent
or bankrupt, or if any assignment is made of the other party's property for the
benefit of its creditors or if a receiver, conservator, trustee in bankruptcy or
other similar officer is appointed by a court of competent jurisdiction to take
charge of all or any substantial part of the other party's property, or if a
petition is filed by or against the other party under any provision of the
Bankruptcy Code now or hereafter enacted, and such proceeding is not dismissed
within sixty (60) days after filing, or if a petition is filed by the other
party under any provision of the Bankruptcy Code now or hereinafter enacted.

9.B. TERMINATION FOR CONVENIENCE. At any time after the In-Service Date,
Customer may terminate this Agreement for convenience (a "Termination for
Convenience"), by written notice to SES Americom, provided at least *** days
prior to the effective date of such termination, provided that, on the effective
date of such termination, Customer shall pay to SES Americom an amount equal to
*** The Termination Payment shall constitute Customer's sole obligation in the
event of a Termination for Convenience, and, for the avoidance of doubt,
Customer shall have no further duties or obligations to SES Americom hereunder,
except as expressly set forth in Subsection 9.F(2), provided that, except as
provided in Subsection 2.A(2), Customer understands and agrees that any attempt
to recover some or all of the Option Payment at any time or pay less than the
Termination Payment in connection with a Termination for Convenience would be a
breach of this Agreement and entitle SES Americom to terminate the Agreement for
breach under Section 9.A and recover the Termination Value.

9.C. TERMINATION FOR DELAY OR FORCE MAJEURE.

***

9.D. REFUNDS. In the event of the expiration of this Agreement pursuant to
Section 9.F(1), or in the event of termination by Customer or wrongful
termination by SES Americom pursuant to this Agreement, SES Americom shall
refund any portion of the MRC paid by Customer to SES Americom which relates to
Service not provided by SES Americom, and no further MRC or other amounts shall
be due for the period following expiration or termination. By way of
clarification, this Section 9.D shall not limit Customer's rights under this
Agreement, at law, in equity or otherwise, in the event of Termination for
Default or otherwise by Customer.

9.E. TERMINATION LIABILITY. ***

9.F. EXPIRATION OF AGREEMENT/ SURVIVAL.

***

9.F(2) Neither party shall have any further obligations or liability to the
other under this Agreement in the event of the termination or expiration of this
Agreement in accordance with this Article 9, except for any obligations or
liability (a) arising prior to such termination or expiration, (b) expressly
arising upon or as a result of such termination or expiration, (c) expressly
described in this Agreement as surviving such expiration or termination, or (d)
arising as a result of or in connection with the representations and warranties
in Article 3.

***Certain confidential portions of this exhibit were omitted by means of
redacting a portion of the text. Copies of the exhibit containing the redacted
portions have been filed separately with the Securities and Exchange Commission
subject to a request for confidential treatment pursuant to Rule 24b-2 under the
Securities Exchange Act.

                                       10
<PAGE>
                                                                  Execution Copy

***

                         ARTICLE 10. GENERAL PROVISIONS

10.A. FORCE MAJEURE. If a Force Majeure Event under this Agreement has occurred
and is continuing, then the performance obligations of the party directly
affected by such Force Majeure Event under this Agreement shall be tolled for
the duration of such Force Majeure Event and such party shall not be liable to
the other by reason of any delay or failure in performance of this Agreement
which arises out of such Force Majeure Event; provided that the party directly
affected by such Force Majeure Event shall promptly take and continue to take
all reasonable actions to abate such Force Majeure Event as soon as possible. If
a payment is made late as a result of a Force Majeure Event (e.g., unscheduled
closure of the banking settlement system), then interest at 30-day LIBOR shall
be compounded monthly and paid from the due date until the date actually paid.
If Service is unavailable as a result of a Force Majeure Event affecting the
Satellite, then Customer's obligation to pay the MRC shall be suspended during
such period Service is unavailable and shall resume upon the Service becoming
available. A "Force Majeure Event" means acts of God, acts of the other party,
acts of government authority, strikes or other labor disturbances, or any other
cause beyond the reasonable control of that party, that (1) as to SES Americom,
relates to or affects its ability to provide the Service, or (2) as to either
party, relates to or affects that party's ability to make a payment.

10.B. NO IMPLIED LICENSE. The provision of services or the conveying of any
information under this Agreement shall not convey any license by implication,
estoppel or otherwise, under any patents or other intellectual property rights
of Customer or SES Americom, SES Global SA, and their Affiliates, contractors
and vendors (including Vendor).

10.C. NO THIRD-PARTY RIGHTS; NO FIDUCIARY RELATIONSHIP. Nothing contained in
this Agreement shall be deemed or construed by the parties or by any third party
to create any rights, obligations or interests in third parties; or to create
the relationship of principal and agent, partnership or joint venture or any
other fiduciary relationship or association among the parties.

10.D. NO WAIVER; REMEDIES CUMULATIVE. No waiver, alteration, or modification of
any of the terms of this Agreement will be binding unless in writing and signed
by all parties. All remedies and rights hereunder and those available in law or
in equity shall be cumulative and the exercise by a party of any such right or
remedy shall not preclude the exercise of any other right or remedy available
under this Agreement in law or in equity.

10.E. COSTS AND ATTORNEYS' FEES. In any action brought with respect to this
Agreement by one party hereto against the other party hereto, in addition to any
other money damages awarded by a court of competent jurisdiction, the prevailing
party shall be entitled to recover from the other party its reasonable costs,
including reasonable attorneys' fees, in successfully bringing or defending
against such action.

10.F. EXCLUSIVE JURISDICTION.

10.F(1) Each party hereby irrevocably and unconditionally (a) agrees that any
suit, action or proceeding against SES Americom by Customer with respect to this
Agreement shall be instituted only in the trial court of Princeton, New Jersey,
or the U.S. District Court for the District of New Jersey (and appellate courts
from any of the foregoing), as Customer may elect in its sole discretion, (b)
agrees that any suit, action or proceeding against Customer by SES Americom with
respect to this Agreement shall be instituted only in the trial court of Denver,
Colorado, or the U.S. District Court for the District of Colorado (and appellate
courts from any of the foregoing), as SES Americom may elect in its sole
discretion, (c) consents and submits, for itself and its property, to the
jurisdiction of such courts for the purpose of any such suit, action or
proceeding instituted against it by the other, and (d) agrees that a final
judgment in any such suit, action or proceeding shall be conclusive and may be
enforced in other jurisdictions by suit on the judgment or in any other manner
provided by law.

***Certain confidential portions of this exhibit were omitted by means of
redacting a portion of the text. Copies of the exhibit containing the redacted
portions have been filed separately with the Securities and Exchange Commission
subject to a request for confidential treatment pursuant to Rule 24b-2 under the
Securities Exchange Act.

                                       11
<PAGE>
                                                                  Execution Copy

10.F(2) Each party hereby irrevocably and unconditionally agrees that service of
all writs, process and summonses in any suit, action or proceeding pursuant to
Subsection 10.F(1) may be effected by the mailing of copies thereof by
registered or certified mail, postage prepaid, to such party at its address for
notices pursuant to Section 1.E, such service to become effective 30 days after
such mailing, provided that nothing contained in this Subsection 10.F(2) shall
affect the right of either party to serve process in any other manner permitted
by law.

10.F(3) Each party hereby irrevocably and unconditionally (a) waives any
objection which it may now or hereafter have to the laying of venue of any suit,
action or proceeding arising out of or relating to this Agreement brought in any
court specified in clause (a) or clause (b) of Subsection 10.F(1) (as
applicable), (b) waives any claim that any such suit, action or proceeding
brought in any such court has been brought in an inconvenient forum and (c)
agrees not to plead or claim either of the foregoing.

10.F(4) The provisions of this Section 10.F shall survive expiration or
termination of this Agreement indefinitely.

10.G. SPECIFIC PERFORMANCE. Each party recognizes that any material breach of
the terms of this Agreement would give rise to irreparable harm to the other
party for which money damages would not be an adequate remedy, and accordingly
agrees that, any term of this Agreement to the contrary notwithstanding, in
addition to all other remedies available to it, each party shall be entitled to
enforce the terms of this Agreement by a decree of specific performance against
the other party, in each case without the necessity of proving the inadequacy of
money damages, provided that Customer shall not be entitled to receive the
benefit of such specific performance with respect to any action by SES Americom
that would: (1) pose or allow to remain a threat to the health and stable
operation of the Satellite; or (2) result in a violation by SES Americom of any
applicable law or regulation, or any coordination agreement or requirement. Such
remedy shall not be deemed the exclusive remedy for breach of this Agreement,
but shall be in addition to all other remedies that a party may have at law, in
equity, under contract or otherwise. The provisions of this Section 10.G shall
survive expiration or termination of this Agreement indefinitely.

10.H. HEADINGS; SEVERABILITY; CUSTOMER PURCHASE ORDERS. All titles and headings
in this Agreement are for reference purposes only; they will not affect the
meaning or construction of the terms of this Agreement. If any part or parts of
this Agreement are held to be invalid, the remaining parts of the Agreement will
continue to be valid and enforceable. Customer agrees that any purchase order or
other similar document that Customer may issue in connection with this Agreement
will be for Customer's internal purposes only and, therefore, even if
acknowledged by SES Americom, will not in any way add to, subtract from, or in
any way modify the terms and conditions of this Agreement.

10.I. ASSIGNMENT. ***

10.J. INTER-PARTY WAIVER. Customer, on behalf of itself and its officers,
employees, Affiliates, agents, insurers, owners and customers, agrees to accept
the inter-party waiver and related indemnity provisions required by the
applicable Launch Services Agreement for a launch, modified so as to apply to
Customer and the launch services provider. SES Americom likewise, on behalf of
itself and its officers, employees, Affiliates, agents, insurers, owners and
customers, agrees to accept the inter-party waiver and related indemnity
provisions required by the applicable Launch Services Agreement for a launch,
modified so as to apply to SES Americom and the launch services provider. In no
event shall such inter-party waiver and related indemnity provisions have any
effect on the rights, obligations and liabilities of and between Customer and
SES Americom under this Agreement.

10.K. PUBLICITY. Neither party shall in any way or in any form publicize or
advertise in any manner this Agreement or the Services to be provided pursuant
to this Agreement without the express written approval (which shall not be
unreasonably withheld) of the other party, obtained in advance, for each item of
advertising or publicity. The foregoing prohibition shall include but not be
limited to news releases, letters,

***Certain confidential portions of this exhibit were omitted by means of
redacting a portion of the text. Copies of the exhibit containing the redacted
portions have been filed separately with the Securities and Exchange Commission
subject to a request for confidential treatment pursuant to Rule 24b-2 under the
Securities Exchange Act.

                                       12
<PAGE>
                                                                  Execution Copy

correspondence, literature, promotional materials or displays of any nature or
form. Each request for approval hereunder shall be submitted in writing to the
representative designated in writing; and approval, in each instance, shall be
effective only if in writing and signed by said representative. Nothing herein
shall prevent either party from providing the FCC, or any other governmental
agency, information concerning this Agreement as required by law or in response
to a request for information by such governmental agency. Notwithstanding the
foregoing, either party may refer to the fact that SES Americom is providing the
Service to Customer without the other party's prior approval so long as such
statements are limited to a statement of such fact and are not an endorsement
(positive or negative) of any product or service.

10.L. ITAR. Information exchanged under this Agreement may be subject to U.S.
export control laws and regulations, such as the U.S. International Traffic in
Arms Regulations ("ITAR") or the Export Administration Act. The parties agree
that information subject to the export control laws and regulations shall not be
disclosed or transferred to a third party without first obtaining written
approval from the disclosing party and complying with all applicable U.S. export
control laws and regulations.

10.M. ENTIRE AGREEMENT. This Agreement contains the entire and exclusive
understanding between the parties concerning the subject matter hereof and
supersedes all prior communications and understandings between them relative to
the subject matter hereof.

                             ARTICLE 11. DEFINITIONS

         As used in this Agreement:

***

A.       "Affiliate" means, with respect to a party, any person or entity (1)
         10% or more of the capital securities which on an as-converted basis
         are owned by, or (2) directly or indirectly controlling, controlled by,
         or under common control with, such party at the time when the
         determination of affiliation is being made. For purposes of this
         definition, the term "control" (including the correlative meanings of
         the terms "controlled by" and "under common control with"), as used
         with respect to a person or entity, shall mean the possession, directly
         or indirectly, of the power to (a) direct or cause the direction of
         management policies of such person or entity, whether through the
         ownership of voting securities or by contract or otherwise, or (b)
         select a majority of the Board of Directors of such person or entity.

B.       "Agreement" shall have the meaning specified in Section 1.A.

C.       ***

D.       "AMC-14 Satellite" shall have the meaning specified in Section 1.A.

***

E.       "AMC-15 Agreement" shall mean the Satellite Service Agreement among the
         parties effective as of March 21, 2003, as previously amended by
         Amendment #1 effective as of July 10, 2003, and as such agreement may
         be amended in the future from time to time in accordance with its
         terms.

F.       "AMC-15 Satellite" shall have the meaning specified in Section 1.A of
         the AMC-15 Agreement.

***

G.       "Business Day" means Monday through Friday, 8:30 a.m. to 5:00 p.m.
         (local time in New York City, New York) exclusive of banking holidays
         observed in New York City.

***Certain confidential portions of this exhibit were omitted by means of
redacting a portion of the text. Copies of the exhibit containing the redacted
portions have been filed separately with the Securities and Exchange Commission
subject to a request for confidential treatment pursuant to Rule 24b-2 under the
Securities Exchange Act.

                                       13
<PAGE>
                                                                  Execution Copy

H.       "Construction Contract" shall have the meaning specified in Section
         1.A.

I.       "Continuation Payments" shall have the meaning specified in Section
         9.G.

J.       "Coordination Agreements" shall have the meaning specified in
         Subsection 3.A(7).

K.       "Customer" shall have the meaning specified in the preamble paragraph.

***

L.       "Customer's Designees" shall have the meaning specified in Subsection
         4.B(2).

M.       "DBS Service" shall mean direct-to-home video services provided to
         residential and/or commercial subscribers ***

N.       "EIRP" shall mean the effective isotropic radiated power.

O.       "End-of-Life" means the date on which, in SES Americom's reasonable
         judgment, a satellite should be taken out of service because of
         insufficient fuel.

P.       "Effective Date" shall have the meaning specified in the preamble
         paragraph.

Q.       "Extended Term" shall have the meaning specified in Section 1.C.

***

R.       "Force Majeure Event" shall have the meaning specified in Section 10.A.

***

S.       "In-Service" means that the Satellite *** is deployed in an SES Orbital
         Location or a Customer Orbital Location, and, following SES Americom
         testing and verification of the entire Satellite, SES Americom
         determines in its reasonable business judgment that the Satellite or
         all usable capacity thereof, is ready for commercial operation in
         accordance with the applicable Technical Performance Specifications,
         provided that the Satellite is not a Satellite Failure. SES Americom
         agrees that it shall provide written notice of such determination to
         Customer on the date that SES Americom makes its determination.

T.       "In-Service Date" means the date on which the Satellite *** is
         In-Service.

U.       "Incremental Costs" shall have the meaning specified in Subsection
         2.G(7).

V.       "Initial Period" shall have the meaning specified in Subsection 2.I(1).

***

W.       "ITAR" shall have the meaning ascribed to that term in Section 10.L.

X.       "ITU" means the International Telecommunications Union.

Y.       "Launch Service Agreement" means the agreement to be executed between
         SES Americom and a launch provider for the launch of the Satellite.

***

***Certain confidential portions of this exhibit were omitted by means of
redacting a portion of the text. Copies of the exhibit containing the redacted
portions have been filed separately with the Securities and Exchange Commission
subject to a request for confidential treatment pursuant to Rule 24b-2 under the
Securities Exchange Act.

                                       14
<PAGE>
                                                                  Execution Copy

Z.       "MRC" shall have the meaning specified in Section 2.B.

***

AA.      "Orbital Location" shall have the meaning specified in Section 1.A.

BB.      "Partial Loss" shall mean any failure of a Transponder to operate in
         accordance with the Technical Performance Specifications that does not
         result in a Satellite Failure.

***

CC.      "Prime Rate" shall mean the "prime rate" of interest as shown in the
         Money and Investing Section of the Wall Street Journal as of the
         applicable date.

***

DD.      "Satellite" shall mean the AMC-14 Satellite ***

***

EE.      "Service" shall have the meaning specified in Section 1.A.

FF.      "Service Term" shall have the meaning specified in Section 1.C.

GG.      "SES Americom" shall have the meaning specified in the preamble
         paragraph.

***

HH.      "Technical Performance Specifications" shall have the meaning specified
         in Subsection 1.B(1).

II.      "Termination for Convenience" shall have the meaning specified in
         Section 9.B.

JJ.      "Termination for Default" shall have the meaning specified in Section
         9.A.

KK.      "Termination Payment" shall have the meaning specified in Section 9.B.

LL.      "Termination Value" shall have the meaning specified in Section 9.E.

MM.      "Transponder" means a communication path by which a signal is
         transmitted using the Satellite.

NN.      "TT&C" shall have the meaning specified in Section 5.A.

OO.      "User's Guide" shall have the meaning specified in Subsection 4.B(1).

***

This Agreement contains the complete and exclusive understanding of the parties
with respect to the subject matter hereof and supersedes all prior negotiations
and agreements between the parties with respect thereto. To the extent that any
Attachment may be inconsistent with the text of the Agreement, the text of the
Agreement shall control.

***Certain confidential portions of this exhibit were omitted by means of
redacting a portion of the text. Copies of the exhibit containing the redacted
portions have been filed separately with the Securities and Exchange Commission
subject to a request for confidential treatment pursuant to Rule 24b-2 under the
Securities Exchange Act.

                                       15
<PAGE>
                                                                  Execution Copy

ECHOSTAR SATELLITE CORPORATION            SES AMERICOM, INC., as agent for
                                          SES AMERICOM CALIFORNIA, INC.
                                          and SES AMERICOM COLORADO, INC.

By:                                       By:
    ---------------------------------         ----------------------------------
(Signature)                               (Signature)

Name:                                     Name:
      -------------------------------           --------------------------------
(Typed or Printed Name)                   (Typed or Printed Name)

Title:                                    Title:
       ------------------------------            -------------------------------

ECHOSTAR COMMUNICATIONS CORPORATION,
solely as to the obligation set forth
in Section 3.C of this Agreement

By:
    ---------------------------------
(Signature)

Name:
      -------------------------------
(Typed or Printed Name)

Title:
       ------------------------------

***Certain confidential portions of this exhibit were omitted by means of
redacting a portion of the text. Copies of the exhibit containing the redacted
portions have been filed separately with the Securities and Exchange Commission
subject to a request for confidential treatment pursuant to Rule 24b-2 under the
Securities Exchange Act.

                                       16

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00057-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00057-of-00352.parquet"}]]