Document:

Credit Agreement

 Exhibit 10.5 
  
 AGREEMENT 
  
 US$1,000,000,000 
 CREDIT FACILITY 
  
 For 
  
 SEASPAN CORPORATION 
 as Borrower

  
 Arranged by 
  
 CITIGROUP GLOBAL MARKETS LIMITED and FORTIS CAPITAL CORP. 
  
 with 
  
 CITIGROUP GLOBAL MARKETS LIMITED 
 CREDIT SUISSE 
 DNB NOR BANK ASA 
 FORTIS CAPITAL CORP. 
 LANDESBANK HESSEN-THÜRINGEN 
 as Mandated Lead Arrangers 
  
 with

 FORTIS CAPITAL CORP. 
 as Facility Agent

  
 DATED [•], 2005 

 CONTENTS 
  

					
	 Clause

	  	 	  	Page

	 1.
	  	Interpretation	  	1
	 2.
	  	Facility and Purpose	  	24
	 3.
	  	Conditions Precedent	  	25
	 4.
	  	Utilisation	  	26
	 5.
	  	Repayment	  	27
	 6.
	  	Prepayment and Cancellation	  	27
	 7.
	  	Interest	  	32
	 8.
	  	Terms	  	33
	 9.
	  	Market Disruption	  	34
	 10.
	  	Taxes	  	35
	 11.
	  	Increased Costs	  	36
	 12.
	  	Retention Account	  	37
	 13.
	  	Payments	  	38
	 14.
	  	Representations	  	41
	 15.
	  	Information Covenants	  	45
	 16.
	  	General Covenants	  	48
	 17.
	  	Financial Covenants	  	62
	 18.
	  	Valuation	  	66
	 19.
	  	Default	  	67
	 20.
	  	Security	  	71
	 21.
	  	The Administrative Parties	  	74
	 22.
	  	Evidence and Calculations	  	78
	 23.
	  	Fees	  	78
	 24.
	  	Indemnities and Break Costs	  	79
	 25.
	  	Expenses	  	82
	 26.
	  	Waiver of Consequential Damages	  	82
	 27.
	  	Amendments and Waivers	  	82
	 28.
	  	Changes to the Parties	  	84
	 29.
	  	Disclosure of Information	  	86
	 30.
	  	Set-Off	  	87
	 31.
	  	Pro Rata Sharing	  	87
	 32.
	  	Severability	  	88
	 33.
	  	Counterparts	  	88
	 34.
	  	Notices	  	89
	 35.
	  	Language	  	90
	 36.
	  	Governing Law	  	90
	 37.
	  	Enforcement	  	90

  

									
	Schedule

	  	 
	1.	  	 	  	Original Parties	  	92
	 	  	 	  	Part 1	  	Original Owners and the Initial Vessels	  	92
	 	  	 	  	Part 2	  	Original Lenders	  	93
	2.	  	 	  	Initial Condition Precedent Documents	  	94
	 	  	 	  	Part 1	  	Tranche A Initial Conditions Precedent Documents	  	94
	 	  	 	  	Part 2	  	Tranche B Initial Conditions Precedent Documents	  	1
	3.	  	 	  	Conditions Subsequent to Drawing	  	5
	4.	  	 	  	Payments	  	6
	 	  	 	  	Part 1	  	Form of Request	  	6
	 	  	 	  	Part 2	  	Payment Advice	  	7

					
	5.	  	Calculation of the Mandatory Cost	  	8
	6.	  	Form of Transfer Certificate	  	10
	7.	  	Repayment Schedule	  	12
	8.	  	Compliance Certificate	  	13
	9.	  	Annual Compliance Certificate	  	14
	10.	  	Manager’s Certificate	  	15
	11.	  	Estimated Addback Relating to Delivered Vessels Depreciation	  	16
	12.	  	Standing Payment Instructions	  	17
		
	 Appendix

	  	 
	1.	  	Form of Insurances Assignment	  	18
	2.	  	Form of Mortgage	  	19
	3.	  	Form of Deed of Covenants	  	20
	4.	  	Form of Management Agreement Assignment	  	21
	5.	  	Form of Swap Mortgage	  	22
	6.	  	Form of Swap Deed of Covenants	  	23
	7.	  	Form of Swap Agreement Assignment	  	24
	8.	  	Form of Deed of Proceeds and Priorities	  	25
	9.	  	Form of Charter Guarantee Assignment	  	26
		
	 Signatories
	  	27

 THIS AGREEMENT is dated [•], 2005 
  
 BETWEEN: 
  

	(1)	SEASPAN CORP., a corporation incorporated according to the laws of the Republic of the Marshall Islands with its registered office at [•] (the Borrower);

  

	(2)	CITIGROUP GLOBAL MARKETS LIMITED and FORTIS CAPITAL CORP. as joint arrangers (in this capacity the Arrangers); 

  

	(3)	CITIGROUP GLOBAL MARKETS LIMITED, CREDIT SUISSE, DNB NOR BANK ASA, LANDESBANK HESSEN-THÜRINGEN and FORTIS CAPITAL CORP. as mandated lead arrangers;

  

	(4)	THE FINANCIAL INSTITUTIONS listed in Part 2 of Schedule 1 (Original Lenders) as original lenders (the Original Lenders); and 

  

	(5)	FORTIS CAPITAL CORP. as facility agent (in this capacity the Facility Agent). 

  
 IT IS AGREED as follows: 
  

	1.	INTERPRETATION 

  

	1.1	Definitions 

  

	    	In this Agreement: 

  
 Account Bank means Fortis Bank N.V. whose registered office is situated at Coolsingel 93, 3012 AE Rotterdam, the Netherlands or any other bank or
financial institution with which, with the prior written consent of the Facility Agent (acting in accordance with the instructions of the Majority Lenders), the Retention Account is at any time held. 
  

	    	Acquisition Date means: 

  

	 	(a)	in respect of a new Additional Vessel, the date upon which such Additional Vessel is delivered under the relevant Shipbuilding Contract; or 

  

	 	(b)	in respect of a used Additional Vessel, the date upon which title to the used Additional Vessel passes to the Borrower. 

  
 Additional Vessel Loan means any Tranche B Loan as is drawn down in
respect of the financing of an Additional Vessel and which is in the maximum principal amount of the Maximum Available Tranche B Amount. 
  
 Additional Vessels means any new or used container vessel to be acquired by the Borrower (other than an Initial Vessel) and Additional Vessel
means any of them. 
  
 Administrative Party means the
Arrangers or the Facility Agent. 
  
 Affiliate means a
Subsidiary or a Holding Company of a person or any other Subsidiary of that Holding Company. 
  
 Agreement means this credit agreement, including any schedules or appendices hereto, as amended from time to time. 
  

					
	 	 	1	 	21 July 2005

 Amortisation Commencement Date means the date falling five years and three months from the earlier
of the final Delivery Date and 31st December, 2007. 
  
 Annual Compliance Certificate means the form of certificate attached at Schedule 9 (Annual Compliance Certificate).

  
 Applicable Law means any or all applicable law
(whether civil, criminal or administrative), common law, statute, statutory instrument, treaty, convention, regulation, directive, by-law, demand, decree, ordinance, injunction, resolution, order, judgment, rule, permit, licence or restriction (in
each case having the force of law) and codes of practice or conduct, circulars and guidance notes generally accepted and applied by the global container shipping industry, in each case of any government, quasi-government, supranational, federal,
state or local government, statutory or regulatory body, court, agency or association relating to all laws, rules, directives and regulations, national or international, public or private in any applicable jurisdiction from time to time. 

 
 Applicable Time means, in respect of the Delivered Vessels,
immediately following and on the date of the first Drawing under the Delivered Vessels Loan or, in respect of the Subsequent Vessels either (i) if there is a Drawing in respect of the Loan which relates to such Subsequent Vessel, immediately
following and on the date of such Drawing or (ii) if there is no Drawing, within ten (10) Business Days of the Delivery Date of that Subsequent Vessel (irrespective of whether a drawing is made in respect of the Loan relating to that Subsequent
Vessel) or in respect of any Additional Vessel, immediately following and on the date of the Drawing under the Loan for the financing of such Additional Vessel. 
  
 Approved Valuers means [            ],
[            ] and [            ] or such other independent reputable shipbroker acceptable to the Facility Agent (acting on the
instructions of the Majority Lenders) and the Borrower.1 Availability Period means the period from and
including the Closing Date, to and including: 
  

	 	(i)	in respect of a Tranche A Loan, the earlier of (x) the date falling two (2) Business Days after the Delivery Date of Vessel 23 and (y) 31st December, 2007; and 

  

	 	(ii)	in respect of a Tranche B Loan, 31st December, 2006. 

  
 Break Costs means the amount (if any) which a Lender is entitled to receive under this Agreement as compensation if any part of a Loan or overdue
amount is prepaid other than on the last day of a Term for such Loan or overdue amount or, as the case may be, the amount (if any) which any Swap Counterparty is entitled to receive under any Swap Agreement in the event that such Swap Agreement is
terminated early, each as determined pursuant to Clause 24.3 (Break Costs) hereof. 
  
 Builder means Samsung Heavy Industries Co. Ltd., a corporation organised and existing under the laws of the Republic of Korea with its registered office at Samsung Yoksam Building, 647-9, Yoksam-Dong,
Kangnam-Ku, Seoul, Korea, or, from time to time, any builder of an Additional Vessel. 
  
 Business Day means a day (other than a Saturday or a Sunday) on which banks are open for general business in London, England, New York, the United States of America and Vancouver, Canada. 
  

	1	Seaspan to provide details once confirmed 

  

					
	 	 	2	 	21 July 2005

 Cash and Cash Equivalents shall have the meaning given to it in Clause 17.1 (Financial
Covenants). 
  
 Change of Control means, after the
occurrence of an IPO, the acquisition, directly or indirectly, by any person or group other than the Seaspan Group of beneficial ownership of more than fifty (50) per cent. of the aggregate outstanding voting power of the equity interests of the
Borrower. 
  
 Charter Default means any of the following
events: 
  

	 	(a)	a change of control of the Charterer as described in Clause 6.3 that results in the Borrower having an obligation to prepay all or any of the Loans; or 

  

	 	(b)	a default by the Charterer that results in the Borrower having an obligation to prepay all or any of the Loans pursuant to Clauses 16.12 (Partial prepayments or additional security)
or 16.24(b) (Termination of Time Charter). 

  
 Charter Guarantee means in relation to each of Vessel 13, Vessel 14, Vessel 15, Vessel 16, Vessel 17, Vessel 18, Vessel 19, Vessel 20 and Vessel 21, the guarantee provided by the Charter Guarantor in favour of the relevant Original Owner in
respect of charterhire under the relevant Time Charter by Lykes, as novated by such Original Owner to the Borrower pursuant to a novation agreement, 
  
 Charter Guarantee Assignment means, in relation to each of Vessel 13, Vessel, 14 Vessel, 15 Vessel 16, Vessel 17, Vessel 18, Vessel 19, Vessel 20
and Vessel 21, the assignment of the relevant Charter Guarantee to be granted by the relevant the Borrower in favour of the Facility Agent in the form attached at Appendix 9. 
  
 Charter Guarantor means CP Ships Limited of 44 Chipman Hill, 10th Floor, PO Box 7289, Station A, Saint John, New Brunswick, Canada E2L 4S6. 
  
 Charterers means CSCL, Lykes or any substitute charterer from time to time in accordance with the provisions of
Clause 16.24 (Termination of Time Charter) or any charterer from time to time of an Additional Vessel and Charterer means any of them. 
  
 Closing Date means the later of (i) the date of this Agreement and (ii) the closing date of the IPO. 
  
 Commitment means: 
  

	 	(a)	for an Original Lender, the aggregate amount set opposite its name in Part 2 of Schedule 1 (Original Lenders) under the headings Tranche A Commitments and Tranche B
Commitments and the amount of any other commitment to advance funds under this Agreement, it acquires; and 

  

	 	(b)	for any other Lender, the amount of any commitment to advance funds under this Agreement, it acquires, 

  
 to the extent not cancelled, transferred or reduced under this Agreement. 
  
 Compliance Certificate means the form of certificate attached at
Schedule 8 (Compliance Certificate). 
  
 Confidentiality
Undertaking means a confidentiality undertaking in a form agreed between the Borrower and the Facility Agent. 
  
 CSCL means China Shipping Container Lines. 
  

					
	 	 	3	 	21 July 2005

 Date of Total Loss means, in respect of a Vessel, the date of Total Loss of that Vessel which date
shall be deemed to have occurred: 
  

	 	(a)	in the case of an actual total loss, on the actual date and at the time that Vessel was lost or, if such date is not known, on the date on which that Vessel was last reported;

  

	 	(b)	in the case of a constructive total loss, upon the date and at the time notice of abandonment is given to the Insurers for the time being (provided a claim for total loss is
admitted by such Insurers) or, if such Insurers do not forthwith admit such a claim, at the date and at the time at which either a total loss is subsequently admitted by the Insurers or a total loss is subsequently adjudged by a competent court of
law or arbitration tribunal to have occurred; 

  

	 	(c)	in the case of a compromised, agreed or arranged total loss, on the date upon which a binding agreement as to such compromised, agreed or arranged total loss has been entered into
by the Insurers; 

  

	 	(d)	in the case of requisition for title or other compulsory acquisition, on the date upon which the relevant requisition for title or other compulsory acquisition occurs; and

  

	 	(e)	in the case of capture, seizure, arrest, detention, requisition for hire or confiscation by any government or by persons acting or purporting to act on behalf of any government or
by any other person which deprives the Borrower or, as the case may be, the Charterer of the use of that Vessel for more than sixty (60) days, upon the expiry of the period of sixty (60) days after the date upon which the relevant capture, seizure,
arrest, detention, requisition or confiscation occurred. 

  
 Deed of Covenants means, in respect of a Vessel, the deed of covenants entered into or to be entered into by the Borrower and the Facility Agent collated to the Mortgage over that Vessel in the form of Appendix 3. 
  
 Default means: 
  

	 	(a)	an Event of Default; or 

  

	 	(b)	an event which would be (with the expiry of a grace period, the giving of notice or the making of any determination under the Finance Documents or any combination of them) an Event
of Default. 

  
 Delivered Vessels means
Vessel 1, Vessel 2, Vessel 3, Vessel 4, Vessel 5, Vessel 6, Vessel 7, Vessel 8, Vessel 9 and Vessel 10 being the Delivered Vessels as listed in Part 1 of Schedule 1 and Delivered Vessel means any of them. 
  
 Delivered Vessels Loan means such part of the Facility as is drawn
down against Mortgages on each of the Delivered Vessels and is in the maximum principal amount of the lesser of: 
  

	 	(a)	60 per cent. of the aggregate Initial Market Values of the Delivered Vessels; and 

  

	 	(b)	four hundred and fifty million Dollars (US$450,000,000). 

  
 Delivery Date means, in respect of a Subsequent Vessel, the date of actual delivery of that Subsequent Vessel to the Borrower under the terms of
the relevant Shipbuilding Contract and, in respect of an Additional Vessel, the date of actual delivery of that Additional Vessel to the Borrower. 
  

					
	 	 	4	 	21 July 2005

 Dollars or US$ means the lawful currency for the time being of the United States of
America. 
  
 DPP means the deed of proceeds and priorities
to be entered into by, inter alios, the Borrower, the Facility Agent and the Swap Counterparties prior to any Swap Mortgage being granted to the Swap Counterparties in the form attached at Appendix 8 
  
 Drawing means, in respect of a Loan under the Facility, the amount of
the advance made by the Lenders. 
  
 Environment means:

  

	 	(a)	any land including, without limitation, surface land and sub-surface strata, sea bed or river bed under any water (as referred to below) and any natural or man-made structures;

  

	 	(b)	water including, without limitation, coastal and inland waters, surface waters, ground waters and water in drains and sewers; and 

  

	 	(c)	air including, without limitation, air within buildings and other natural or man-made structures above or below ground. 

  
 Environmental Affiliate means the Borrower, the Shareholder and each
Manager together with their respective employees and all of those persons for whom the Borrower, the Shareholder or any Manager is responsible under any Applicable Law in respect of any activities undertaken in relation to any of the Vessels.

  
 Environmental Approvals means any permit, licence,
approval, ruling, variance, exemption or other authorisation required under applicable Environmental Laws. 
  
 Environmental Claim means any claim by any person or persons or any governmental, judicial or regulatory authority which arises out of any breach,
contravention or violation of Environmental Law or of the existence of any liability or potential liability arising from such breach, contravention or violation or the presence of Hazardous Material in contravention of Environmental Laws. In this
context, claim means: a claim for damages, compensation, fines, penalties or any other payment of any kind whether or not similar to the foregoing; an order or direction to take, or not to take, certain action or to desist from or suspend certain
action by any governmental, judicial or regulatory authority; and any form of enforcement or regulatory action. 
  
 Environmental Laws means any or all Applicable Law relating to or concerning: 
  

	 	(a)	pollution or contamination of the Environment, any ecological system or any living organisms which inhabit the Environment or any ecological system; 

  

	 	(b)	the generation, manufacture, processing, distribution, use (including abuse), treatment, storage, disposal, transport or handling of Hazardous Materials; and

  

	 	(c)	the emission, leak, release, spill or discharge into the Environment of noise, vibration, dust, fumes, gas, odours, smoke, steam, effluvia, heat, light, radiation (of any kind),
infection, electricity or any Hazardous Material and any matter or thing capable of constituting a nuisance or an actionable tort or breach of statutory duty of any kind in respect of such matters, 

  
 including, without limitation, the following laws of the United States of
America: the Comprehensive Environmental Response, Compensation and Liability Act of 1980, as amended, the Hazardous Materials Transportation Act, as amended, the Oil Pollution Act of 1990, as amended, the 

  

					
	 	 	5	 	21 July 2005

 
Resource Conservation and Recovery Act, as amended, and the Toxic Substances Control Act, as amended, together, in each case, with the regulations
promulgated and the guidance issued pursuant thereto. 
  
 Event of Default means an event specified as such in Clause 19 (Default) of this Agreement. 
  
 Excess Risks means, in respect of a Vessel: 
  

	 	(a)	the proportion of claims for general average, salvage and salvage charges which are not recoverable as a result of the value at which that Vessel is assessed for the purpose of such
claims exceeding her hull and machinery insured value; and 

  

	 	(b)	collision liabilities not recoverable in full under the hull and machinery insurance by reason of those liabilities exceeding such proportion of the insured value of that Vessel as
is covered by the hull and machinery insurance. 

  
 Existing Credit Facility means any existing credit facility whatsoever provided to any Subsidiary of the Shareholder in respect of any one or more of the Initial Vessels. 
  
 Facility means the credit facility made available under this Agreement. 
  
 Facility Office means in respect of a Lender, the office through
which that Lender will perform its obligations under this Agreement from time to time, which at the date of this Agreement is, in respect of Fortis Capital Corp., Connecticut, United States of America; in respect of Citibank, N.A., [•]; in
respect of DnB Nor Bank ASA, New York, United States of America; in respect of Credit-Suisse, Basel, Switzerland; in respect of Landesbank Hessen-Thüringen, New York, United States of America; or such other address as a Lender may notify to the
Facility Agent from time to time. 
  
 Fee Letter means any
letter entered into by reference to this Agreement between one or more Administrative Parties and the Borrower setting out the amount of certain fees referred to in this Agreement. 
  
 Final Maturity Date means the earlier of (a) the seventh anniversary of the Delivery Date of the Vessel which is
delivered latest in time and (b) 31st October, 2014. 
  
 Finance Document means: 
  

	 	(a)	this Agreement; 

  

	 	(b)	each Security Document; 

  

	 	(c)	the DPP; 

  

	 	(d)	each Swap Agreement; 

  

	 	(e)	the Fee Letters; 

  

	 	(f)	each Manager’s Undertaking; 

  

	 	(g)	a Transfer Certificate; and 

  

	 	(h)	any other document designated as such by the Facility Agent and the Borrower. 

  

Finance Party means a Lender, a Swap Counterparty or an Administrative Party. 
  

					
	 	 	6	 	21 July 2005

 Financial Indebtedness means any indebtedness for or in respect of: 
  

	 	(a)	moneys borrowed; 

  

	 	(b)	any acceptance credit; 

  

	 	(c)	any bond, note, debenture, loan stock or other similar instrument; 

  

	 	(d)	any redeemable preference share; 

  

	 	(e)	any agreement treated as a finance or capital lease in accordance with U.S. GAAP; 

  

	 	(f)	receivables sold or discounted (otherwise than on a non-recourse basis); 

  

	 	(g)	the acquisition cost of any asset to the extent payable after its acquisition or possession by the party liable where the deferred payment is arranged primarily as a method of
raising finance or financing the acquisition of that asset; 

  

	 	(h)	any derivative transaction protecting against or benefiting from fluctuations in any rate or price (and, except for non-payment of an amount, the then mark to market value of the
derivative transaction will be used to calculate its amount); 

  

	 	(i)	any other transaction (including any forward sale or purchase agreement) which has the commercial effect of a borrowing; 

  

	 	(j)	any counter-indemnity obligation in respect of any guarantee, indemnity, bond, letter of credit or any other instrument issued by a bank or financial institution; or

  

	 	(k)	any guarantee, indemnity or similar assurance against financial loss of any person. 

  
 Hazardous Material means any element or substance, whether natural or artificial, and whether consisting of gas,
liquid, solid or vapour, whether on its own or in any combination with any other element or substance, which is listed, identified, defined or determined by any Environmental Law or other Applicable Law to be, to have been, or to be capable of being
or becoming harmful to mankind or any living organism or damaging to the Environment, including, without limitation, oil (as defined in the United States Comprehensive Environmental Response, Compensation and Liability Act of 1980, as amended).

  
 Hedging Policy means the hedging policy implemented
and to be maintained by the Borrower as determined by the Borrower’s board of directors and as agreed by the Facility Agent by its acknowledgement of the hedging policy letter addressed to the Facility Agent from the Borrower dated on or before
the date of the first Drawing under the Delivered Vessels Loan. 
  
 Holding Company means a holding company within the meaning of section 736 of the Companies Act 1985. 
  
 Increased Cost means: 
  

	 	(a)	an additional or increased cost; 

  

	 	(b)	a reduction in the rate of return under a Finance Document or on its overall capital; or 

  

	 	(c)	a reduction of an amount due and payable under any Finance Document, 

  

					
	 	 	7	 	21 July 2005

 which is incurred or suffered by a Finance Party or any of its Affiliates but only to the extent
attributable to that Finance Party having entered into any Finance Document or funding or performing its obligations under any Finance Document. 
  
 Initial Market Value means: 
  

	 	(i)	in respect of a Delivered Vessel, the market value of that Vessel as at the Closing Date (determined in accordance with Clause 18 (Valuation)); 

  

	 	(ii)	in respect of a Subsequent Vessel, the market value of that Vessel determined at the Closing Date (determined in accordance with Clause 18 (Valuation) having regard to the Delivery
Date of such Vessel in accordance with the relevant Shipbuilding Contract); or 

  

	 	(iii)	in respect of an Additional Vessel, the market value of that Vessel as at the Delivery Date of that Additional Vessel (determined in accordance with Clause 18 (Valuation)).

  
 Initial Vessels means together the
Delivered Vessels and the Subsequent Vessels and Initial Vessel means any of them. 
  
 Insurances Assignment means, in respect of a Vessel, the assignment of the Obligatory Insurances granted or to be granted in favour of the Facility Agent by the Borrower in the form of Appendix 1 together with
any and all notices and acknowledgements entered into in connection therewith. 
  
 Insurers means the underwriters or insurance companies with whom any Obligatory Insurances are effected and the managers of any protection and indemnity or war risks association in which any of the Vessels may
at any time be entered. 
  
 IPO means an initial public
offering of the shares of the Borrower. 
  
 ISM Code means
the International Safety Management Code (including the guidelines on its implementation), adopted by the International Maritime Organization Assembly as Resolutions A.741(18) and A.788(19), as the same may have been or may be amended or
supplemented from time to time. The terms “safety management system”, “Safety Management Certificate”, “Document of Compliance” and “major non-conformity” shall have the same meanings as are given to them in
the ISM Code. 
  
 ISPS Code means the International Ship
and Port Facility Security Code adopted by the International Maritime Organization Assembly as the same may have been or may be amended or supplemented from time to time. 
  
 Lender means: 
  

	 	(a)	an Original Lender; or 

  

	 	(b)	any person which becomes a party to this Agreement after the date of this Agreement pursuant to Clause 28.2 (Assignment and transfers by Lenders); 

  
 and Lenders means all of them. 
  
 LIBOR means for a Term of any Loan or overdue amount: 
  

	 	(a)	the applicable Screen Rate; or 

  

	 	(b)	if no Screen Rate is available for the relevant currency or Term of that Loan or overdue amount, the arithmetic mean (rounded upward to four decimal places) of the rates, as
supplied to the Facility Agent at its request, quoted by the Reference Banks to leading banks in the London interbank market, 

  

					
	 	 	8	 	21 July 2005

 as of 11.00 a.m. on the second London Business Day before the start of the Term for the offering of
deposits in the currency of that Loan or overdue amount for a period comparable to that Term. 
  
 Loan to Value Ratio means, at any date of determination, the ratio of the aggregate principal amount of the outstanding Loans less any Cash and Cash Equivalents secured to the Lenders pursuant to the Security
Documents to the aggregate of the latest Market Values of all of the Vessels actually delivered or, in the case of an individual Vessel, the ratio of (i) the proportion which the outstanding Loans less any Cash and Cash Equivalents, as is equivalent
to the proportion which the Initial Market Value of that Vessel bears to the aggregate Initial Market Value of all of the Vessels actually delivered, bears to the aggregate outstanding loans to (ii) the Market Value of that Vessel. 
  
 Loans means together the Delivered Vessels Loan, the Subsequent
Vessel Loans and any Additional Vessel Loan (each a Loan). 
  
 London Business Day means a day (other than a Saturday or a Sunday) on which banks are open for business in London. 
  
 Losses means each and every liability, loss, charge, claim, demand, action, proceeding, damage, judgment, order or other sanction, enforcement,
penalty, fine, fee, commission, interest, lien, salvage, general average, cost and expense of whatsoever nature suffered or incurred by or imposed on the Lenders. 
  
 Lykes means Lykes Lines LLC. 
  

Majority Lenders means Lenders: 
  

	 	(a)	whose share in the outstanding Loans and whose undrawn Commitments then aggregate not less than 66 2/3 per cent. of the aggregate of all the outstanding Loans and the undrawn Commitments of all the Lenders; 

  

	 	(b)	if there is no Loan then outstanding, whose undrawn Commitments then aggregate not less than 66 2/3 per cent. of the Total Commitments; or 

  

	 	(c)	if there is no Loan then outstanding and the Total Commitments have been reduced to zero, whose Commitments aggregated not less than 66 2/3 per cent. of the Total Commitments immediately before the reduction. 

  
 Management Agreement means the management agreement dated on or about the date of this Agreement between the Borrower
and the Manager. 
  
 Management Agreement Assignment means
the assignment of the Management Agreement granted or to be granted in favour of the Facility Agent by the Borrower in the form of Appendix 5 together with any and all notices and acknowledgements entered into in connection therewith, one to be
entered into between the Manager and the Borrower. 
  
 Manager means Seaspan Ship Management Ltd. of 2600-200 Granville Street, Vancouver BC, Canada V6C 1S4 or such other professional manager or managers as may be approved by the Facility Agent (acting in accordance with the instructions
of the Majority Lenders) from time to time. 
  

					
	 	 	9	 	21 July 2005

 Manager’s Undertaking means a letter of undertaking to be issued by each Manager to the
Facility Agent confirming it shall not make a claim to security ranking ahead of the Lenders’ security in respect of a Vessel in form and substance satisfactory to the Facility Agent. 
  
 Mandatory Cost means the properly evidenced cost of complying with
certain regulatory requirements, expressed as a percentage rate per annum and calculated by the Facility Agent under Schedule 5 (Calculation of the Mandatory Cost). 
  
 Margin means, on each Rate Fixing Day, the rate (expressed as a percentage per annum) set out in the second column
below opposite the number (expressed as a percentage) which represents the Loan to Value Ratio for that date: 
  

			
	 Loan to Value Ratio (%)

	 	 Margin (% rate per annum)

	 less than 30.01 per cent.
	 	0.75
	 30.01 per cent. to 35 per cent. (inclusive)
	 	0.80
	 35.01 per cent. to 40 per cent. (inclusive)
	 	0.85
	 40.01 per cent. to 45 per cent. (inclusive)
	 	0.90
	 45.01 per cent. to 50 per cent. (inclusive)
	 	0.95
	 50.01 per cent. to 55 per cent. (inclusive)
	 	1.00
	 55.01 per cent. to 60 per cent. (inclusive)
	 	1.05
	 60.01 per cent. to 65 per cent. (inclusive)
	 	1.10
	 65.01 per cent. to 70 per cent. (inclusive)
	 	1.15
	 greater than 70.00 per cent.
	 	1.25

  
 Market Value
means, in respect of a Vessel, the Initial Market Value or, as the case may be, any market value of that Vessel subsequently calculated in accordance with Clause 18 (Valuation). 
  
 Material Adverse Effect means a material adverse effect on: 
  

	 	(a)	the ability of the Borrower to perform all of its payment obligations under this Agreement; or 

  

	 	(b)	the validity or enforceability of this Agreement. 

  
 Maximum Available Tranche A Loan Amount means: 
  

	 	(a)	in respect of the Delivered Vessels, the lower of: 

  

	 	(i)	60 per cent. of the aggregate Initial Market Values of the Delivered Vessels; and 

  

	 	(ii)	four hundred and fifty million Dollars (US$450,000,000); and 

  

	 	(b)	in respect of a Subsequent Vessel, the lower of: 

  

	 	(i)	40 per cent. of the Initial Market Value of that Vessel; and 

  

					
	 	 	10	 	21 July 2005

	 	(ii)	when aggregated with the aggregate outstanding principal amount of the Tranche A Loans, seven hundred and fifty million Dollars (US$750,000,000). 

  
 Maximum Available Tranche B Loan Amount means, in respect of an
Additional Vessel, the lower of: 
  

	 	(a)	85 per cent. of the lower of (x) the Initial Market Value of that Additional Vessel and (y) the price at which the Borrower has acquired that Vessel; and 

 

	 	(b)	when aggregated with the aggregate outstanding principal amount of the Tranche B Loans, two hundred and fifty million Dollars (US$250,000,000); and 

  

	 	(c)	the amount calculated by multiplying sixteen thousand five hundred Dollars (US$16,500) by the total capacity that Additional Vessel (measured in teu, using the teu capacity declared
by the Classification Society); and 

  

	 	(d)	when aggregated with the aggregate outstanding principal amount of the Tranche A Loans and the Tranche B Loans, 55 per cent. of the then aggregate Market Value of all the Vessels
which have been delivered. 

  
 Maximum Facility
Amount means one billion Dollars (US$1,000,000,000) being the total of the Maximum Available Tranche A Loan Amounts and the Maximum Available Tranche B Loan Amounts for all Vessels. 
  
 Maximum Tranche A Facility Amount means seven hundred and fifty million Dollars (US$750,000,000). 
  
 Maximum Tranche B Facility Amount means two hundred and fifty million
Dollars (US$250,000,000). 
  
 Measurement Period means, at
any time, the last four (4) fiscal quarters for the Borrower provided always that until four (4) fiscal quarters have elapsed from the date of this Agreement, the period from the date of this Agreement until the date of determination. 
  
 Mortgage means, in respect of a Vessel, the first priority [Hong
Kong] ship mortgage to be given by the Borrower in favour of the Facility Agent, (i) in respect of each of the Delivered Vessels, on the date of the first Drawing under the Delivered Vessels Loan, and (ii) in respect of each Subsequent Vessel and
any Additional Vessel, on the Delivery Date of that Vessel in the form attached at Appendix 2. 
  
 Obligatory Insurances means in respect of each Vessel: 
  

	 	(a)	all contracts and policies of insurance and all entries in clubs and/or associations which are from time to time required to be effected and maintained in accordance with this
Agreement in respect of each of the Vessels; and 

  

	 	(b)	all benefits under the contracts, policies and entries under paragraph (a) above and all claims in respect of them and the return of premiums. 

  
 Original Balance Sheet means the unaudited balance sheet of the
Borrower prepared as at [·]2. 
  

	2	Seaspan to provide details 

  

					
	 	 	11	 	21 July 2005

 Original Owners means the companies listed in Part 1 of Schedule 1 and Original Owner means
any of them. 
  
 Party means a party to this Agreement or
any Finance Document. 
  
 Permitted Liens means, in respect
of a Vessel: 
  

	 	(a)	Security Interests created by the Security Documents; 

  

	 	(b)	Security Interests created by the Swap Mortgage; 

  

	 	(c)	liens for unpaid crew’s wages including wages of the master and stevedores employed by the Vessel, outstanding in the ordinary course of trading for not more than one calendar
month after the due date for payment; 

  

	 	(d)	liens for salvage; 

  

	 	(e)	liens for classification or scheduled dry docking or for necessary repairs to that Vessel whose aggregate cost does not exceed US$1,500,000 at any one time in respect of that
Vessel; 

  

	 	(f)	liens for collision; 

  

	 	(g)	liens for master’s disbursements incurred in the ordinary course of trading; 

  

	 	(h)	statutory and common law liens of carriers, warehousemen, mechanics, suppliers, materials men, repairers or other similar liens, including maritime liens, in each case arising in
the ordinary course of business, outstanding for not more than one month whose aggregate value does not exceed US$500,000; and 

  

	 	(i)	solely for the period from the date of this Agreement up to an including, in respect of a Delivered Vessel, the date of the first Drawing under the Delivered Vessels Loan or, in
respect of a Subsequent Vessel or any Additional Vessel, the date of the first Drawing under the Loan relating to such Vessel, Security Interests relating to such Vessel created pursuant to the terms of the relevant Existing Credit Facility in
favour of the lenders under such facility, 

  
 in
the case of paragraphs (b) to (h) inclusive provided that the amounts which give rise to such liens are paid when due (or, in the case of paragraph (c) or (h) above, within one month of such amount being outstanding) or, if not paid when due are
being disputed in good faith by appropriate proceedings (and for the payment of which adequate reserves or security are at the relevant time maintained or provided), provided further that such proceedings, whether by payment of adequate security
into Court or otherwise, do not give rise to a material risk of the relevant Vessel or any interest therein being seized, sold, forfeited or otherwise lost or of criminal liability on the Facility Agent. 
  
 Post-Delivery Period means: 
  

	 	(i)	in respect of a Delivered Vessel, the period from the date of the first Drawing under the Delivered Vessels Loan until the Final Maturity Date; or 

  

	 	(ii)	in respect of a Subsequent Vessel or any Additional Vessel, the period from the Delivery Date of that Vessel until the Final Maturity Date. 

  

					
	 	 	12	 	21 July 2005

 Pro Rata Share means: 
  

	 	(a)	for the purpose of determining a Lender’s share in a utilisation of the Facility, the proportion which its Commitment bears to the Total Commitments; and

  

	 	(b)	for any other purpose on a particular date: 

  

	 	(i)	the proportion which a Lender’s share of the Loans (if any) bears to all the Loans; 

  

	 	(ii)	if there is no Loan outstanding on that date, the proportion which its Commitment bears to the Total Commitments on that date; or 

  
 if the Total Commitments have been cancelled, the proportion which its
Commitment bore to the Total Commitments immediately before being cancelled. 
  
 Quarter Day means each of the 30th March, 30th June, 30th September, 30th December in each year provided always that such date is a Business Day. 

 
 Rate Fixing Day means two (2) London Business Days before the
first day of the relevant Term for a Drawing, or unless market practice differs in the London interbank market for a currency, in which case the Rate Fixing Day for that currency will be determined by the Facility Agent in accordance with market
practice in the London interbank market (and if quotations would normally be given by leading banks in the London interbank market on more than one day, the Rate Fixing Day will be the last of those days). 
  
 Reference Banks means Fortis Capital Corp., Citibank, N.A. and DnB
Nor Bank ASA and any other bank or financial institution appointed as such by the Facility Agent (acting on the instructions of the Majority Lenders) under this Agreement. 
  
 Related Contracts means any or all of the following (as the context requires): 
  

	 	(a)	the Obligatory Insurances; 

  

	 	(b)	the Time Charters; 

  

	 	(c)	the Management Agreement; and 

  

	 	(d)	the Charter Guarantees. 

  
 Release means an emission, spill, release or discharge into or upon the air, surface water, groundwater, or soils of any Hazardous Materials for
which the Borrower has any liability under Environmental Law, except in accordance with a valid Environmental Approval. 
  
 Repayment Date means each date which is either (or both) a Tranche A Repayment Date and/or a Tranche B Repayment Date. 
  
 Repayment Instalment means, in respect of a Loan, each instalment
which is either (or both) a Tranche A Repayment Instalment and/or a Tranche B Repayment Instalment payable for repayment of that Loan in accordance with the relevant Repayment Schedule. 
  
 Repayment Schedule means the Schedule of Repayment Dates as detailed in Schedule 7 (Repayment Schedule), to be
replaced as required in accordance with Clause 5.1(b) (Repayment of the Loans). 
  

					
	 	 	13	 	21 July 2005

 Request means a request made by the Borrower for a Drawing, substantially in the form of Part 1 of
Schedule 4 (Form of Request). 
  
 Required Amount means at
any date of determination, 120 per cent. of the aggregate principal amount of the outstanding Loans in respect of the Vessels actually delivered. 
  
 Required Insurance Amount means, in respect of a Vessel, at any date of determination, 125 per cent. of the proportion of the aggregate principal
amount of the outstanding Loans which is equal to the proportion that the latest Market Value of that Vessel bears to the aggregate of the latest Market Values of all of the Vessels actually delivered. 
  
 Requisition Compensation means, in respect of a Vessel, all moneys or
other compensation payable by reason of requisition for title to, or other compulsory acquisition of, that Vessel including requisition for hire. 
  
 Retention Account means the bank account to be opened by the Borrower with the Account Bank and designated “Seaspan Corp. – Retention
Account”. 
  
 Retention Account Charge means the
fixed charge or, as the case may be, pledge in respect of all monies standing to the credit from time to time of the Retention Account granted or to be granted by the Borrower in favour of the Facility Agent on or about the date of this Agreement,
together with any and all notices and acknowledgements entered into in connection therewith. 
  
 Screen Rate means, for LIBOR, and in respect of a Term, the percentage rate per annum for a period substantially the same as the relevant Term displayed on page 3750 of the Telerate screen. If the relevant page
is replaced or the service ceases to be available, the Facility Agent may specify another page or service displaying the appropriate rate. 
  
 Seaspan Group means: 
  

	 	(a)	any of K&K Enterprises, Dennis Washington or Dennis Washington’s estate, spouse, and/or descendants; or 

  

	 	(b)	any revocable trust for the benefit of Dennis Washington, his spouse or his descendants; or 

  

	 	(c)	an Affiliate of the Borrower that directly or indirectly through one or more intermediaries controls or is controlled by or is under common control with the Borrower.

  
 For the purposes of paragraph (c)
control means the possession, directly or indirectly, of the power to direct or cause the direction of the management and policies of a person, whether through the ownership of voting stock, by contract or otherwise and controls and
controlled shall be construed in like manner.3 
  
 Secured Liabilities means all present and future obligations and liabilities (actual or contingent) of the Borrower
to the Finance Parties or any of them under or in connection with any Finance Document. 
  
 Security Agreements means: 
  

	 	(a)	the Mortgages; 

  

	 	(b)	the Deeds of Covenant; 

  

	3	BHT to propose language to include the Tiger entities within this definition. 

  

					
	 	 	14	 	21 July 2005

	 	(c)	the Swap Mortgages; 

  

	 	(d)	the Swap Deeds of Covenant; 

  

	 	(e)	the Insurances Assignments; 

  

	 	(f)	the Management Agreement Assignment; 

  

	 	(g)	the Time Charter and Earnings Assignments; 

  

	 	(h)	the Charter Guarantee Assignments; 

  

	 	(i)	the Retention Account Charge; 

  

	 	(j)	the Swap Agreement Assignments; and 

  

	 	(k)	any other document designated as such in writing by the Borrower and the Facility Agent. 

  
 Security Assets means any asset which is the subject of a Security Interest created by a Security Document.

  
 Security Document means: 
  

	 	(a)	each Security Agreement; and 

  

	 	(b)	any other document evidencing or creating security over any asset of the Borrower to secure any obligation of the Borrower to the Finance Parties or any of them under the Finance
Documents. 

  
 Security Interest means any
mortgage, pledge, lien, charge, assignment, hypothecation or security interest or any other agreement or arrangement having a similar effect. 
  
 Shareholder means Seaspan Container Lines Limited.4 
  
 Shipbuilding Contract means: 
  

	 	(a)	in respect of an Initial Vessel, the agreement between the Builder and relevant Original Owner as amended and novated pursuant to a novation agreement between the Builder, the
Original Owner and the Borrower pursuant to which the Builder agreed to build and deliver that Vessel to the Borrower; and 

  

	 	(b)	in respect of an Additional Vessel, any agreement between a builder and the Borrower pursuant to which that builder shall agree to build and deliver such Additional Vessel to the
Borrower. 

  
 S & P means Standard &
Poor’s Ratings Group and any successor thereto. 
  
 Subsequent Vessel Loans means Vessel Loan 11, Vessel Loan 12, Vessel Loan 13, Vessel Loan 14, Vessel Loan 15, Vessel Loan 16, Vessel Loan 17, Vessel Loan 18, Vessel Loan 19, Vessel Loan 20, Vessel Loan 21, Vessel Loan 22 and Vessel
Loan 23. 
  

	4	BHT to confirm whether this is appropriate. 

  

					
	 	 	15	 	21 July 2005

 Subsequent Vessels means Vessel 11, Vessel 12, Vessel 13, Vessel 14, Vessel 15, Vessel 16, Vessel
17, Vessel 18, Vessel 19, Vessel 20, Vessel 21, Vessel 22 and Vessel 23 being the Subsequent Vessels as listed in Part 1 of Schedule 1 and Subsequent Vessel means any of them. 
  
 Subsidiary means: 
  

	 	(a)	a subsidiary within the meaning of section 736 of the Companies Act 1985; and 

  

	 	(b)	unless the context otherwise requires, a subsidiary undertaking within the meaning of section 258 of the Companies Act 1985. 

  
 Swap Agreements means, if any, each of the ISDA Master Agreements
(and the confirmation thereunder) entered into or to be entered into in respect of interest rate swaps in respect of the Loans (or any part of the Loans) by any Swap Counterparty and the Borrower in pursuance of the Hedging Policy. 
  
 Swap Agreement Assignment means, in respect of each Swap Agreement,
the assignment of that Swap Agreement to be granted by the Borrower in favour of the Facility Agent (for and on behalf of itself and the Finance Parties) in the form attached at Appendix 7, together with any and all notices and acknowledgements
entered into in connection therewith. 
  
 Swap
Counterparty means any party to a Swap Agreement who provides interest rate hedging facilities to the Borrower in respect of the Loans. 
  
 Swap Deed of Covenants means, in respect of a Vessel, the deed of covenants entered into or to be entered into by the Borrower and the Swap
Counterparties (or any agent or security trustee on their behalf) collateral to the Swap Mortgage over that Vessel in the form of Appendix 6 
  
 Swap Mortgage means, in respect of a Vessel, the second priority [Hong Kong] ship mortgage to be given by the Borrower in favour of the Swap
Counterparties (or any agent or security trustee on their behalf), (i) in respect of each of the Delivered Vessels, on the date of the first drawing under the Delivered Vessels Loan or, if later, the date of relevant Swap Agreement, and (ii) in
respect of each Subsequent Vessel and any Additional Vessel, on the Delivery Date of that Vessel in the form attached at Appendix 5 
  
 Tax means any tax, levy, impost, duty or other charge or withholding of a similar nature (including, without limitation, any penalty or interest
payable in connection with any failure to pay or any delay in paying any of the same). 
  
 Tax Deduction means a deduction or withholding for or on account of Tax made from a payment under a Finance Document by a payer for or on account of Tax imposed on that payer by any jurisdiction from which such
payment is made or within which such payment arises. 
  
 Tax
Payment means a payment made by the Borrower to a Lender in any way relating to a Tax Deduction or under any indemnity given by the Borrower in respect of Tax under any Finance Document. 
  
 Term means each period determined under this Agreement by reference
to which interest payable on a Loan or an overdue amount is calculated. 
  
 Time Charter means, in respect of an Initial Vessel, the time charterparty entered into by the relevant Original Owner and the relevant Charterer (or, in the case of CSCL, China Shipping (Group) Company) as
novated by such Original Owner to the Borrower pursuant to a novation agreement (and, in the case of a time charterparty with CSCL, as novated by China Shipping 
  

					
	 	 	16	 	21 July 2005

 (Group) Company to CSCL) or the time charterparty entered into by the Borrower and the relevant Charterer
or, in respect of either an Initial Vessel or any other Vessel, such other time charterparty entered into from time to time in respect of a Vessel in accordance with this Agreement. 
  
 Time Charter and Earnings Assignment means, in respect of a Vessel, the assignment of the Time Charter and the
Earnings granted or to be granted by the Borrower on or about the date of this Agreement in favour of the Facility Agent together with any and all notices and acknowledgements entered into in connection therewith. 
  
 Total Commitments means the aggregate of the Commitments of all the
Lenders. 
  
 Total Loss means in relation to a Vessel:

  

	 	(a)	actual, constructive, compromised, agreed or arranged total loss of that Vessel; 

  

	 	(b)	requisition for title or other compulsory acquisition of that Vessel otherwise than by requisition for hire; 

  

	 	(c)	capture, seizure, arrest, detention, or confiscation of that Vessel by any government or by persons acting or purporting to act on behalf of any government or by any other person
which deprives the Borrower of that Vessel or as the case may be the Charterer of the use of that Vessel for more than sixty (60) days after that occurrence; and 

  

	 	(d)	requisition for hire of that Vessel by any government or by persons acting or purporting to act on behalf of any government which deprives the Borrower or as the case may be the
Charterer of the use of that Vessel for a period of sixty (60) days, other than a charter of the Vessel to a government or government agency approved by the Borrower and by the Facility Agent (acting on the instructions of the Majority Lenders).

  
 Tranche A Commitment means: 

 

	 	(a)	for an Original Lender, the amount set opposite its name in Part 2 of Schedule 1 (Original Lenders) under the heading Tranche A Commitments together with the amount of any other
commitment to advance any part of a Tranche A Loan under this Agreement it acquires; and 

  

	 	(b)	for any other Lender, the amount of any commitment to advance any part of a Tranche A Loan under this Agreement it acquires, 

  
 to the extent not cancelled, transferred or reduced under this Agreement.

  
 Tranche A Lenders means the lenders detailed in Part 2
of Schedule 1 as Tranche A Lenders together with any New Lenders in respect of a Tranche A Loan. 
  
 Tranche A Loans means the Delivered Vessels Loan and the Subsequent Vessel Loans and Tranche A Loan means any of them. 
  
 Tranche A Pro Rata Share means: 
  

	 	(a)	for the purpose of determining a Tranche A Lender’s share in a utilisation of the Tranche A Loans, the proportion which its Commitment in respect of Tranche A bears to the
Total Commitments in respect of Tranche A; and 

  

	 	(b)	for any other purpose on a particular date: 

  

	 	(i)	the proportion which a Tranche A Lender’s share of the Tranche A Loans (if any) bears to all the Tranche A Loans; 

  

					
	 	 	17	 	21 July 2005

	 	(ii)	if there is no Tranche A Loan outstanding on that date, the proportion which its Commitment in relation to Tranche A bears to the Total Commitments in relation to Tranche A on that
date; or 

  

	 	(iii)	if the Total Commitments in relation to Tranche A have been cancelled, the proportion which its Commitment in relation to Tranche A bore to the Total Commitments in relation to
Tranche A immediately before being cancelled. 

  
 Tranche A Repayment Date means, in respect of the Tranche A Loans, each of the eight (8) dates falling at quarterly intervals as detailed in the Repayment Schedule for the Tranche A Loans, the first such date falling on the
Amortisation Commencement Date, and the final such date falling on the Final Maturity Date. 
  
 Tranche A Repayment Instalment means, in respect of the Tranche A Loans, each instalment which is payable for repayment of the Tranche A Loans in accordance with the Repayment Schedule for the Tranche A Loans.

  
 Tranche B Commitment means: 
  

	 	(a)	for an Original Lender, the amount set opposite its name in Part 2 of Schedule 1 (Original Lenders) under the heading Tranche B Commitments together with the amount of any other
commitment to advance any part of a Tranche B Loan under this Agreement it acquires; and 

  

	 	(b)	for any other Lender, the amount of any commitment to advance any part of a Tranche B Loan under this Agreement it acquires, 

  
 to the extent not cancelled, transferred or reduced under this Agreement.

  
 Tranche B Lenders means the lenders detailed in Part 2
of Schedule 1 as Tranche B Lenders together with any New Lenders in respect of a Tranche B Loan. 
  
 Tranche B Loan means, in respect of an Additional Vessel, all monies advanced to the Borrower by the Tranche B Lenders. 
  
 Tranche B Pro Rata Share means: 
  

	 	(a)	for the purpose of determining a Tranche B Lender’s share in a utilisation of the Tranche B Loans, the proportion which its Commitment in respect of Tranche B bears to the
Total Commitments in respect of Tranche B; and 

  

	 	(b)	for any other purpose on a particular date: 

  

	 	(i)	the proportion which a Tranche B Lender’s share of the Tranche B Loans (if any) bears to all the Tranche B Loans; 

  

	 	(ii)	if there is no Tranche B Loan outstanding on that date, the proportion which its Commitment in relation to Tranche B bears to the Total Commitments in relation to Tranche B on that
date; or 

  

					
	 	 	18	 	21 July 2005

	 	(iii)	if the Total Commitments in relation to Tranche B have been cancelled, the proportion which its Commitment in relation to Tranche B bore to the Total Commitments in relation to
Tranche B immediately before being cancelled. 

  
 Tranche B Repayment Date means, in respect of the Tranche B Loans, each of the eight (8) dates falling at quarterly intervals as detailed in the Repayment Schedule for the Tranche B Loans, the first such date falling on the
Amortisation Commencement Date, and the final such date falling on the Final Maturity Date. 
  
 Tranche B Repayment Instalment means in respect of the Tranche B Loans, each instalment which is payable for repayment of the Tranche B Loans in accordance with the Repayment Schedule for the Tranche B Loans.

  
 Transfer Certificate means a certificate,
substantially in the form of Schedule 6 (Form of Transfer Certificate), with such amendments as the Facility Agent and the Borrower may approve or reasonably require or any other form agreed between the Facility Agent and the Borrower. 

 
 U.S. GAAP means generally accepted accounting principles adopted
and accepted in the United States of America (i) on the date of this Agreement when used in the context of calculating the financed covenants set out in Clause 17 and (ii) otherwise, from time to time. 
  
 Utilisation Date means each date on which the Facility or any part
thereof is utilised. 
  
 Vessel 1 means the 4,250 TEU
vessel built by the Builder with Official Number IMO 9224300 and named CSCL Hamburg. 
  
 Vessel 2 means the 4,250 TEU vessel built by the Builder with Official Number IMO 9224312 and named CSCL Chiwan. 
  
 Vessel 3 means the 4,250 TEU vessel built by the Builder with Official Number IMO 9227015 and named CSCL Ningbo. 
  
 Vessel 4 means the 4,250 TEU vessel built by the Builder with
Official Number IMO 9227027 and named CSCL Dalian. 
  
 Vessel
5 means the 4,250 TEU vessel built by the Builder with Official Number IMO 9227039 and named CSCL Felixstowe. 
  
 Vessel 6 means the 8,500 TEU vessel built by the Builder with Official Number IMO 9286009 and named CSCL Oceania. 
  
 Vessel 7 means the 8,500 TEU vessel built by the Builder with
Official Number IMO 9286011 and named CSCL Africa. 
  
 Vessel
8 means the 4,250 TEU vessel built by the Builder with Official Number IMO 9290098 and named CSCL Vancouver. 
  
 Vessel 9 means the 4,250 TEU vessel built by the Builder with Official Number IMO 9290103 and named CSCL Sydney. 
  
 Vessel 10 means the 4,250 TEU vessel built by the Builder with
Official Number IMO 9290115 and named CSCL New York. 
  

					
	 	 	19	 	21 July 2005

 Vessel 11 means the 4,250 TEU vessel to be constructed in accordance with the relevant
Shipbuilding Contract with Hull Number 1499 and to be named CSCL Melbourne. 
  
 Vessel 12 means the 4,250 TEU vessel to be constructed in accordance with the relevant Shipbuilding Contract with Hull Number 1500 and to be named CSCL Brisbane. 
  
 Vessel 13 means the 4,250 TEU vessel to be constructed in accordance
with the relevant Shipbuilding Contract with Hull Number 1539 and to be named Lykes Charger. 
  
 Vessel 14 means the 4,250 TEU vessel to be constructed in accordance with the relevant Shipbuilding Contract with Hull Number 1540 and to be named
TMM Guerrero. 
  
 Vessel 15 means the 4,250 TEU vessel to
be constructed in accordance with the relevant Shipbuilding Contract with Hull Number 1541 and to be named Containership Banyan. 
  
 Vessel 16 means the 4,250 TEU vessel to be constructed in accordance with the relevant Shipbuilding Contract with Hull Number 1542 and to be named
Lykes Merchant. 
  
 Vessel 17 means the 4,250 TEU vessel
to be constructed in accordance with the relevant Shipbuilding Contract with Hull Number 1543 and to be named TMM Morelos. 
  
 Vessel 18 means the 4,250 TEU vessel to be constructed in accordance with the relevant Shipbuilding Contract with Hull Number 1544 and to be named
Containership Margosa. 
  
 Vessel 19 means the 4,250 TEU
vessel to be constructed in accordance with the relevant Shipbuilding Contract with Hull Number 1550 and to be named Lykes Victor. 
  
 Vessel 20 means the 4,250 TEU vessel to be constructed in accordance with the relevant Shipbuilding Contract with Hull Number 1551 and to be named
TMM Nuevo Leon. 
  
 Vessel 21 means the 4,250 TEU vessel
to be constructed in accordance with the relevant Shipbuilding Contract with Hull Number 1552 and to be named Containership Cassia. 
  
 Vessel 22 means the 9,600 TEU vessel to be constructed in accordance with the relevant Shipbuilding Contract with Hull Number 1566 and to be named
CSCL Zeebrugge. 
  
 Vessel 23 means the 9,600 TEU vessel
to be constructed in accordance with the relevant Shipbuilding Contract with Hull Number 1568 and to be named CSCL Long Beach. 
  
 Vessels means together the Delivered Vessels and the Subsequent Vessels detailed in Part 1 of Schedule 1 and each Additional Vessel acquired from
time to time and Vessel means any of them. 
  
 Vessel
Loan 11 means such part of the Facility as is drawn down against the Mortgage on Vessel 11 and is in the maximum principal amount of the lesser of: 
  

	 	(c)	40 per cent. of the Initial Market Value of Vessel 11; and 

  

	 	(d)	when aggregated with the aggregate outstanding principal amount of the Tranche A Loans, seven hundred and fifty million Dollars (US$750,000,000). 

  
 Vessel Loan 12 means such part of the Facility as is drawn down
against the Mortgage on Vessel 12 and is in the maximum principal amount of the lesser of: 
  

	 	(a)	40 per cent. of the Initial Market Value of Vessel 12; and 

  

					
	 	 	20	 	21 July 2005

	 	(b)	when aggregated with the aggregate outstanding principal amount of the Tranche A Loans, seven hundred and fifty million Dollars (US$750,000,000). 

  
 Vessel Loan 13 means such part of the Facility as is drawn down
against the Mortgage on Vessel 13 and is in the maximum principal amount of the lesser of: 
  

	 	(a)	40 per cent. of the Initial Market Value of Vessel 13; and 

  

	 	(b)	when aggregated with the aggregate outstanding principal amount of the Tranche A Loans, seven hundred and fifty million Dollars (US$750,000,000). 

  
 Vessel Loan 14 means such part of the Facility as is drawn down
against the Mortgage on Vessel 14 and is in the maximum principal amount of the lesser of: 
  

	 	(a)	40 per cent. of the Initial Market Value of Vessel 14; and 

  

	 	(b)	when aggregated with the aggregate outstanding principal amount of the Tranche A Loans, seven hundred and fifty million Dollars (US$750,000,000). 

  
 Vessel Loan 15 means such part of the Facility as is drawn down
against the Mortgage on Vessel 15 and is in the maximum principal amount of the lesser of: 
  

	 	(a)	40 per cent. of the Initial Market Value of Vessel 15; and 

  

	 	(b)	when aggregated with the aggregate outstanding principal amount of the Tranche A Loans, seven hundred and fifty million Dollars (US$750,000,000). 

  
 Vessel Loan 16 means such part of the Facility as is drawn down
against the Mortgage on Vessel 16 and is in the maximum principal amount of the lesser of: 
  

	 	(a)	40 per cent. of the Initial Market Value of Vessel 16; and 

  

	 	(b)	when aggregated with the aggregate outstanding principal amount of the Tranche A Loans, seven hundred and fifty million Dollars (US$750,000,000). 

  
 Vessel Loan 17 means such part of the Facility as is drawn down
against the Mortgage on Vessel 17 and is in the maximum principal amount of the lesser of: 
  

	 	(a)	40 per cent. of the Initial Market Value of Vessel 17; and 

  

	 	(b)	when aggregated with the aggregate outstanding principal amount of the Tranche A Loans, seven hundred and fifty million Dollars (US$750,000,000). 

  
 Vessel Loan 18 means such part of the Facility as is drawn down
against the Mortgage on Vessel 18 and is in the maximum principal amount of the lesser of: 
  

	 	(a)	40 per cent. of the Initial Market Value of Vessel 18; and 

  

	 	(b)	when aggregated with the aggregate outstanding principal amount of the Tranche A Loans, seven hundred and fifty million Dollars (US$750,000,000). 

  
 Vessel Loan 19 means such part of the Facility as is drawn down
against the Mortgage on Vessel 19 and is in the maximum principal amount of the lesser of: 
  

	 	(a)	40 per cent. of the Initial Market Value of Vessel 19; and 

  

					
	 	 	21	 	21 July 2005

	 	(b)	when aggregated with the aggregate outstanding principal amount of the Tranche A Loans, seven hundred and fifty million Dollars (US$750,000,000). 

  
 Vessel Loan 20 means such part of the Facility as is drawn down
against the Mortgage on Vessel 20 and is in the maximum principal amount of the lesser of: 
  

	 	(a)	40 per cent. of the Initial Market Value of Vessel 20; and 

  

	 	(b)	when aggregated with the aggregate outstanding principal amount of the Tranche A Loans, seven hundred and fifty million Dollars (US$750,000,000). 

  
 Vessel Loan 21 means such part of the Facility as is drawn down
against the Mortgage on Vessel 21 and is in the maximum principal amount of the lesser of: 
  

	 	(a)	40 per cent. of the Initial Market Value of Vessel 21; and 

  

	 	(b)	when aggregated with the aggregate outstanding principal amount of the Tranche A Loans, seven hundred and fifty million Dollars (US$750,000,000). 

  
 Vessel Loan 22 means such part of the Facility as is drawn down
against the Mortgage on Vessel 22 and is in the maximum principal amount of the lesser of: 
  

	 	(a)	40 per cent. of the Initial Market Value of Vessel 22; and 

  

	 	(b)	when aggregated with the aggregate outstanding principal amount of the Tranche A Loans, seven hundred and fifty million Dollars (US$750,000,000). 

  
 Vessel Loan 23 means such part of the Facility as is drawn down
against the Mortgage on Vessel 23 and is in the maximum principal amount of the lesser of: 
  

	 	(a)	40 per cent. of the Initial Market Value of Vessel 23; and 

  

	 	(b)	when aggregated with the aggregate outstanding principal amount of the Tranche A Loans, seven hundred and fifty million Dollars (US$750,000,000). 

  

	1.2	Construction 

  

	(a)	In this Agreement, unless the contrary intention appears, a reference to: 

  

	 	(i)	an amendment includes a supplement, novation, restatement or re-enactment and amended will be construed accordingly; 

  
 assets includes present and future properties, revenues and rights of
every description; 
  
 an authorisation includes an
authorisation, consent, approval, resolution, licence, exemption, filing, registration or notarisation; 
  
 disposal means a sale, transfer, grant, lease or other disposal, whether voluntary or involuntary, and dispose will be construed
accordingly; 
  
 indebtedness includes any obligation
(whether incurred as principal or as surety) for the payment or repayment of money; 
  
 a person includes any individual, company, corporation, unincorporated association or body (including a partnership, trust, joint venture or consortium), government, state, agency, organisation or other entity
whether or not having separate legal personality and their successors in title, permitted assigns and permitted transferees; 
  

					
	 	 	22	 	21 July 2005

 a regulation includes any regulation, rule, official directive, request or guideline (whether or
not having the force of law but, if not having the force of law, being of a type with which any person to which it applies is accustomed to comply) of any governmental, inter-governmental or supranational body, agency, department or regulatory,
self-regulatory or other authority or organisation; 
  

	 	(ii)	a currency is a reference to the lawful currency for the time being of the relevant country; 

  

	 	(iii)	a Default being outstanding means that it has not been cured, remedied or waived; 

  

	 	(iv)	a provision of law is a reference to that provision as extended, applied, amended or re-enacted and includes any subordinate legislation; 

  

	 	(v)	a Clause, a Subclause or a Schedule is a reference to a clause or subclause of, or a schedule to, this Agreement; 

  

	 	(vi)	a Finance Document or another document is a reference to that Finance Document or other document as amended; 

  

	 	(vii)	a time of day is a reference to London time; and 

  

	 	(viii)	words importing the plural shall include the singular and vice versa. 

  

	(b)	Unless the contrary intention appears, a reference to a month or months is a reference to a period starting on (and including) one day in a calendar month and ending
on (but excluding) the numerically corresponding day in the next calendar month or the calendar month in which it is to end, except that: 

  

	 	(i)	if the numerically corresponding day is not a Business Day, the period will end on the next Business Day in that month (if there is one) or the preceding Business Day (if there is
not); 

  

	 	(ii)	if there is no numerically corresponding day in that month, that period will end on the last Business Day in that month; and 

  

	 	(iii)	notwithstanding subparagraph (i) above, a period which commences on the last Business Day of a month will end on the last Business Day in the next month or the calendar month in
which it is to end, as appropriate. 

  

	(c)	Unless expressly provided to the contrary in a Finance Document, a person who is not a party to a Finance Document may not enforce any of its terms under the Contracts (Rights of
Third Parties) Act 1999 and notwithstanding any term of any Finance Document, the consent of any third party is not required for any variation (including any release or compromise of any liability) or termination of that Finance Document.

  

	(d)	Unless the contrary intention appears or unless the context otherwise permits: 

  

	 	(i)	a reference to a Party will not include that Party if it has ceased to be a Party under this Agreement; 

  

					
	 	 	23	 	21 July 2005

	 	(ii)	a word or expression used in any other Finance Document or in any notice given in connection with any Finance Document has the same meaning in that Finance Document or notice as in
this Agreement; and 

  

	 	(iii)	any obligation of the Borrower under the Finance Documents which is not a payment obligation remains in force in accordance with its terms for so long as any payment obligation of
the Borrower is or may be outstanding under the Finance Documents. 

  

	(e)	The headings in this Agreement do not affect its interpretation. 

  

	2.	FACILITY AND PURPOSE 

  

	2.1	Facility 

  
 Subject to the terms of this Agreement, the Lenders make available to the Borrower a term loan facility in a maximum aggregate amount equal to the Maximum
Facility Amount. Each Tranche A Loan shall be capable of being drawn, up to the relevant Maximum Available Tranche A Loan Amount, on the dates described in Clause 4.2(a) (Completion of Requests) and each Tranche B Loan shall be capable of being
drawn, up to the relevant Maximum Available Tranche B Loan Amount, on the dates described in Clause 4.2(a) (Completion of Requests). 
  

	2.2	Loans 

  
 Each Loan may be used only in or towards financing the cost of acquiring the Vessel or Vessels to which it relates or refinancing the whole or any part of
the cost of any Vessel or Vessels which have been purchased by the Borrower from debt or equity. 
  

	2.3	No obligation to monitor 

  
 No Finance Party is obliged to monitor or verify the utilisation of any Loan. 
  

	2.4	Nature of a Finance Party’s rights and obligations 

  
 Unless otherwise agreed by all the Finance Parties: 
  

	 	(a)	the obligations of a Finance Party under the Finance Documents are several; 

  

	 	(b)	failure by a Finance Party to perform its obligations does not affect the obligations of any other Party under the Finance Documents; 

  

	 	(c)	no Finance Party is responsible for the obligations of any other Finance Party under the Finance Documents; 

  

	 	(d)	the rights of a Finance Party under the Finance Documents are separate and independent rights; 

  

	 	(e)	a Finance Party may, except as otherwise stated in the Finance Documents, separately enforce those rights; and 

  

	 	(f)	a debt arising under the Finance Documents to a Finance Party is a separate and independent debt. 

  

					
	 	 	24	 	21 July 2005

	3.	CONDITIONS PRECEDENT 

  

	3.1	Conditions precedent documents 

  

	 	(a)	A Drawing under a Tranche A Loan shall not occur until the Facility Agent has notified the Borrower and the Lenders that it has received all of the documents and evidence set out in
Part 1 of Schedule 2 (Tranche A Initial Conditions Precedent Documents) in form and substance satisfactory to the Facility Agent or that it expects to receive outstanding documents or evidence on or before the date of the relevant Drawing. The
Facility Agent must give this notification to the Borrower and the Lenders promptly upon being so satisfied. 

  

	 	(b)	A Drawing under a Tranche B Loan shall not occur until the Facility Agent has notified the Borrower and the Lenders that it has received all of the documents and evidence set out in
Part 2 of Schedule 2 (Tranche B Initial Conditions Precedent Documents) in form and substance satisfactory to the Facility Agent or that it expects to receive outstanding documents or evidence on or before the date of the relevant Drawing. The
Facility Agent must give this notification to the Borrower and the Lenders promptly upon being so satisfied. 

  

	 	(c)	If the Borrower has made a Request, the Borrower will not to sign a Protocol of Delivery and Acceptance in respect of the Vessel to which the Request relates unless the Facility
Agent has confirmed that the conditions precedent referred to in Clause 3.1(a) or Clause 3.1(b) (as applicable) above have been or will, simultaneously with such signing, be satisfied. 

  

	 	(d)	In respect of the Delivered Vessels, immediately following and on the date of the first Drawing under the Delivered Vessels Loan or, in respect of the Subsequent Vessels either (i)
if there is a Drawing in respect of the Loan which relates to such Subsequent Vessel, immediately following and on the date of such Drawing or (ii) if there is no Drawing, within ten (10) Business Days of the Delivery Date of that Subsequent Vessel
(irrespective of whether a drawing is made in respect of the loan relating to that Subsequent Vessel) or in respect of any Additional Vessel, immediately following and on the date of the Drawing under the Loan for the financing of such Additional
Vessel, the Borrower shall provide to the Facility Agent all documents and evidence set out in Schedule 3 (Conditions Subsequent to Drawdown) in form and substance satisfactory to the Facility Agent. 

  

	 	(e)	The Borrower shall execute a Mortgage and Deed of Covenants and a Swap Mortgage and Swap Deed of Covenants in respect of each Subsequent Vessel no later than the time of delivery of
each subsequent Vessel on the Delivery Date irrespective of whether there is then a Drawing in respect of the Loan relating to that Subsequent Vessel. 

  

	3.2	Further conditions precedent 

  
 The obligations of each Lender to advance any Loan are subject to the further conditions precedent that on both the date of the Request and the
Utilisation Date for that Loan: 
  

	 	(a)	the representations made under Clause 14 (Representations) are correct in all material respects; and 

  

	 	(b)	no Default is outstanding or would result from the Drawing. 

  

					
	 	 	25	 	21 July 2005

	3.3	Maximum Number 

  
 A Request may not be given if, as a result of the Drawing to be made pursuant to that Request, there would be more than an aggregate amount of twenty four
(24) Drawings outstanding under the Tranche A Loans. 
  

	4.	UTILISATION 

  

	4.1	Giving of Requests 

  

	 	(a)	The Borrower may borrow each Loan by giving to the Facility Agent a duly completed Request in respect of a Drawing under that Loan. 

  

	 	(b)	Unless the Facility Agent otherwise agrees, the latest time for receipt by the Facility Agent of a duly completed Request is 11.00 a.m. (New York time) three (3) Business Days prior
to the proposed date for the borrowing. 

  

	 	(c)	Each Request is irrevocable. 

  

	4.2	Completion of Requests 

  
 A Request for a Drawing under a Loan will not be regarded as having been duly completed unless: 
  

	 	(a)           (i)    	in respect of a Drawing under a Tranche A Loan relating to the Delivered Vessels, the Utilisation Date is a Business Day falling within the relevant Availability Period;

  

	 	(ii)	in respect of a Drawing under the Tranche A Loan relating to a Subsequent Vessel, the Utilisation Date is a Business Day falling within the relevant Availability Period but not a
Business Day which falls before the Delivery Date of the Subsequent Vessel to which that Tranche A Loan relates; or 

  

	 	(iii)	in respect of a Drawing under a Tranche B Loan, the Utilisation Date is a Business Day falling within the relevant Availability Period but not a Business Day which falls before the
Acquisition Date of the Additional Vessel to which that Tranche B Loan relates; 

  

	 	(b)	in respect of a Drawing under a Tranche A Loan, it is in an amount not exceeding the Maximum Available Tranche A Loan Amount; 

  

	 	(c)	in respect of the Drawing under a Tranche B Loan, it is in an amount not exceeding the Maximum Available Tranche B Loan Amount; 

  

	 	(d)	in respect of a Drawing under a Tranche A Loan, the amount requested for the Drawing does not exceed, when aggregated with the amounts drawn down or to be drawn down under any other
Requests in respect of Drawings under any other Tranche A Loans, the Maximum Tranche A Facility Amount; 

  

	 	(e)	in respect of the Drawing under a Tranche B Loan, the amount requested for the Drawing does not exceed, when aggregated with the amounts drawn down or to be drawn down under any
other Requests in respect of Drawings under any other Tranche B Loans, the Maximum Tranche B Facility Amount; and 

  

	 	(f)	the proposed Term complies with this Agreement. 

  
 Only one Drawing may be requested in a Request. 
  

					
	 	 	26	 	21 July 2005

	4.3	Advance of Loans 

  

	 	(a)	The Facility Agent must promptly and in any event one (1) Business Day before the Rate Fixing Day notify each Lender of the details of the requested Drawing and the amount of its
share in that Drawing. 

  

	 	(b)	The amount of each Lender’s share of the Loan will be its Tranche A Pro Rata Share or its Tranche B Pro Rata Share (as applicable) on the proposed Utilisation Date.

  

	 	(c)	No Lender is obliged to participate in a Drawing if, as a result, its share in the Loans would exceed its Commitment. 

  

	 	(d)	If the conditions set out in this Agreement have been met, each Lender must make its share in the Drawing available by the Utilisation Date through its Facility Office.

  

	5.	REPAYMENT 

  

	5.1	Repayment of the Loans 

  

	 	(a)	The Borrower must repay the Loans to the Facility Agent on each Repayment Date in accordance with the Repayment Schedule. Each Repayment Instalment will be applied by the Facility
Agent amongst the Loans pro rata against the principal amounts outstanding in respect of each Loan. 

  

	 	(b)	The Facility Agent shall notify the Borrower and the Lenders of any change in the amount or the timing of any Repayment Instalment, as soon as practicable after the occurrence of an
event which will have such an effect. In the event of any such notification, the Facility Agent shall replace the relevant Repayment Schedule attached at Schedule 7 (Repayment Schedule) with a new Repayment Schedule reflecting the correct Repayment
Instalments and the correct Repayment Dates and promptly provide a copy thereof to the Borrower and the Lenders. To the extent that such change results from a reduction in the principal amount of the Loans from that assumed when the then current
Repayment Schedule was produced, any such reduction shall be applied pro rata against the Repayment Instalments. 

  

	 	(c)	In any event, each Loan shall be repaid in full on the Final Maturity Date. 

  

	6.	PREPAYMENT AND CANCELLATION 

  

	6.1	Mandatory prepayment - illegality 

  

	 	(a)	If it becomes, or to the knowledge of any Lender is to become, unlawful in any jurisdiction for a Lender to perform any of its obligations as contemplated by this Agreement or a
Finance Document or to fund or maintain its share in one or more of the Loans (the Event of Illegality), that Lender shall notify the Facility Agent and the Borrower. 

  

	 	(b)	After notification under paragraph (a) above, the Borrower and that Lender shall thereafter consult with each other and use reasonable commercial efforts for a period of thirty (30)
days or in the event that the Event of Illegality takes effect before the expiration of thirty (30) days, for the maximum number of days available before the Event of Illegality takes effect with a view to restructuring the Facility in such a way as
to avoid the effect of the Event of Illegality. 

  

	 	(c)	If agreement cannot be reached between the parties within the period specified in paragraph (b) above: 

  

	 	(i)	the Borrower shall repay the share of that Lender in the relevant Loan or Loans on the date specified in paragraph (d) below; and 

  

					
	 	 	27	 	21 July 2005

	 	(ii)	the Commitment of that Lender will be immediately cancelled. 

  

	 	(d)	The date for repayment of a Lender’s share in a Loan or Loans will be: 

  

	 	(i)	the last day of the current Term of that Loan; or 

  

	 	(ii)	if earlier, the date specified by that Lender in the notice delivered to the Borrower (being no earlier than the last day of any applicable grace period permitted by Applicable
Law). 

  

	6.2	Mandatory prepayment – Change of Control of Borrower 

  

	 	(a)	The Borrower must promptly notify the Facility Agent if it becomes aware of a Change of Control. 

  

	 	(b)	After notification under paragraph (a) above or if the Facility Agent otherwise becomes aware of the same, the Facility Agent may (acting on the instructions of the Majority
Lenders), by notice to the Lenders and the Borrower delivered to the Borrower at any time within thirty (30) days of such notification: 

  

	 	(i)	cancel the Facility; and 

  

	 	(ii)	declare all outstanding Loans to be promptly, and in any event within thirty (30) days, due and payable. 

  
 Any such notice will take effect in accordance with its terms. 
  

	6.3	Mandatory prepayment - change of control of any Charterer 

  

	 	(a)	The Borrower must promptly notify the Facility Agent if it becomes aware of any person or group of persons acting in concert gaining control of any Charterer, be it direct or
indirect. 

  

	 	(b)	If, after notification under paragraph (a) above or if the Facility Agent otherwise becomes aware of the same in respect of the Charterer, the Facility Agent (acting on the
instructions of all of the Lenders, such instructions to be given reasonably) considers that the change of control of the Charterer has, or is reasonably likely when it takes effect to have, a Material Adverse Effect, the Facility Agent shall
promptly notify the Borrower of such conclusion and the provisions of the balance of this Clause 6.3 shall have effect. 

  

	 	(c)	After notification under paragraph (b) above, the Borrower shall have six (6) months to obtain a suitable substitute charterer, such substitute charterer to be satisfactory in all
respects to all of the Lenders. 

  

	 	(d)	Such substitute charterer must enter into any and all documents equivalent in all material respects to the documents currently existing and entered into by the relevant Charterer or
such other documents as are acceptable to the Lenders. 

  

	 	(e)	If the Borrower is unable to obtain a suitable substitute charterer in accordance with the terms of this Clause 6.3, the Borrower shall immediately prepay all outstanding Loans in
relation to the Vessels under charter with the relevant Charterer. 

  

					
	 	 	28	 	21 July 2005

	 	(f)	In paragraph (a) above: 

  
 control means the possession, directly or indirectly, of the power to direct or cause the direction of the management and policies of a person,
whether through the ownership of voting stock, by contract or otherwise by Applicable Law, and controls and controlled shall be construed in like manner; and 
  
 acting in concert has the meaning given to it in the City Code on Takeovers and Mergers. 
  

	6.4	Mandatory prepayment – Termination of Charter 

  

	 	(a)	Unless the Borrower complies with the provisions of Clause 16.24(c) (Termination of Charter) or the Facility Agent receives additional security satisfactory to the Facility Agent
(acting on the instructions of the Majority Lenders), upon the termination of a Time Charter in accordance with 16.26(b) (Termination of Charter), the Borrower shall be obliged to prepay an amount of the Loan relating to the relevant Vessel to
ensure that the Loan to Value Ratio in respect of such Vessel is no greater than 60 per cent. 

  

	 	(b)	Unless the Borrower complies with the provisions of Clause 16.24(d) (Termination of Charter) or the Facility Agent receives additional security satisfactory to the Facility Agent
(acting on the instructions of the Majority Lenders), upon the termination or expiration of a majority of the Time Charters associated with either Lykes or CSCL, the Borrower shall be obliged to prepay the outstanding Loans in relation to the
affected Vessels to ensure that the aggregate of the Market Values of all of the Vessels actually delivered is not less than 150 per cent. of the aggregate principal amount of the outstanding Loans in respect of the Vessels actually delivered.

  

	6.5	Mandatory prepayment - Sale or Total Loss of a Vessel 

  

	 	(a)	Unless, prior to the expiry of the periods referred to in (i) and (ii) below, the Borrower complies with the provisions of Clause 6.6 below, the Borrower shall prepay the proportion
of the Loans then outstanding equal to the proportion that the Initial Market Value of the Vessel the subject of the sale or Total Loss bears to the aggregate Initial Market Value of the Vessels in the following circumstances and at the following
times: 

  

	 	(i)	if that Vessel is sold, on or before the date falling ninety (90) days after the date on which the sale is completed by delivery of that Vessel to a buyer; or

  

	 	(ii)	if there is a Total Loss on or before the date falling ninety (90) days after the Date of Total Loss. 

  

	 	(b)	The Borrower shall, immediately on receipt of the same, credit to the Retention Account the sale or Total Loss proceeds received by the Borrower in respect of the Vessel the subject
of the sale or Total Loss. Such proceeds shall remain in the Retention Account until either (i) they are to be applied in or towards satisfaction of the prepayment obligations of the Borrower pursuant to Clause 6.5(a) and/or (c) or (ii) the
provisions of Clause 6.6 are complied with, in which event such proceeds shall be released to the Borrower. 

  

	 	(c)	In the event that a mandatory prepayment obligation arises under Clause 6.5(a) upon a sale or Total Loss of a Vessel, the Facility Agent shall be entitled to procure immediate
valuations of the remaining Vessel or Vessels in accordance with Clause 18.1(a) (Valuation), at the cost of the Borrower. In the event that such valuation shows that the Required Amount is not satisfied, the Borrower shall be obliged to apply the
balance of any sale proceeds or insurance proceeds after prepayment of the Loan as described in Clause 6.5(a) to the extent required to ensure that the Required Amount is satisfied. Any balance of sale proceeds or insurance proceeds after such
application shall be available immediately to the Borrower. 

  

					
	 	 	29	 	21 July 2005

	6.6	Vessel substitution 

  

	 	(a)	In the event that a Vessel is sold or becomes a Total Loss, the Borrower may, at any time within ninety (90) days after the sale of the Vessel or the Date of Loss of the Vessel,
substitute the Vessel with a replacement vessel in accordance with the terms of this Clause 6.6. The replacement vessel shall be required: 

  

	 	(i)	to undergo a valuation conducted in accordance with Clause 18 (Valuation). 

  

	 	(ii)	as at the time of substitution, to be of at least equal value to the latest Market Value of the Vessel (assuming, where relevant, that the Vessel had not become the subject of a
Total Loss,), provided always that the value of the replacement vessel may be less than the latest Market Value of the Vessel if the Borrower prepays, at the time of substitution, an amount of the Loan relating to such Vessel equal to the difference
between the value of the replacement vessel and the latest Market Value of the Vessel (discounting the effects of any Total Loss upon the value of the Vessel (); and 

  

	 	(iii)	with the same or a similar remaining useful life as the Vessel, 

  
 such determinations to be made by the Facility Agent (acting on the instructions of the Majority Lenders) (the Replacement Vessel). 
  

	 	(b)	Any such request by the Borrower pursuant to Clause 6.6(a) above (the Replacement Request) shall be made to the Facility Agent in writing at least thirty (30) Business Days
prior to the proposed date of substitution (the Substitution Date) and shall be accompanied by evidence of compliance by the Borrower with the conditions specified in Clause 6.6(a) above. 

  

	 	(c)	Subject to satisfaction of the above conditions in full, the Facility Agent shall agree to the replacement of the Vessel by the Replacement Vessel on the Substitution Date provided
that: 

  

	 	(i)	as at the date of the Replacement Request and at the Substitution Date, no Default or Event of Default has occurred and is continuing; 

  

	 	(ii)	there are no material and adverse tax, credit or other relevant implications which it is possible may arise as a result of the substitution; 

  

	 	(iii)	the Facility Agent has received a survey in respect of the Replacement Vessel, reasonably satisfactory to the Facility Agent; and 

  

	 	(iv)	on or prior to the Substitution Date, the Borrower will have executed equivalent Security Documents in relation to the Replacement Vessel, including but not limited to a first
priority ship mortgage in a jurisdiction acceptable to the Facility Agent, an assignment of the earnings, obligatory insurances and any management and charter arrangements in respect of the Replacement Vessel, and such other security documents as
the Agent may in its sole discretion determine appropriate in order to place the Finance Parties in substantially the same position in all respects (mutatis mutandis) as they would have been in prior to the Substitution Date.

  

					
	 	 	30	 	21 July 2005

	 	(d)	All costs in connection with the Replacement Request (including but not limited to the costs of any legal advisors and any costs incurred in valuing and surveying the Replacement
Vessel) shall be for the account of the Borrower. 

  

	6.7	Voluntary prepayment 

  

	 	(a)	The Borrower may, by giving not less than ten (10) days’ prior written notice to the Facility Agent, prepay a Loan in whole or from time to time in part on the last day of any
Term. 

  

	 	(b)	A prepayment must be in a minimum amount of US$5,000,000 and in integral multiples of US$1,000,000 if in excess of US$5,000,000. 

  

	 	(c)	Unless the Facility Agent otherwise agrees, any voluntary prepayment under this Clause 6.7 shall be applied against the Repayment Instalments of the relevant Loan in the inverse
order of their maturity and shall be applied pro rata in respect of the amounts outstanding to the Tranche A Lenders and the Tranche B Lenders. 

  

	 	(d)	No amount prepaid under this Agreement may be reborrowed. 

  

	6.8	Automatic cancellation 

  
 The obligation of a Lender to advance the undrawn amount of its Commitment in relation to the relevant Loan will be automatically cancelled at the close
of business on the last day of the relevant Availability Period. 
  

	6.9	Voluntary cancellation 

  

	 	(a)	The Borrower may, by giving not less than ten (10) days’ prior notice to the Facility Agent, cancel the unutilised amount of the Total Commitments in whole or in part.

  

	 	(b)	Partial cancellation of the Total Commitments must be in a minimum amount of US$5,000,000 and in integral multiples of US$2,500,000 in excess of US$5,000,000.

  

	 	(c)	Any cancellation in whole or in part will be applied against Tranche A and Tranche B, or either of them, as instructed by the Borrower but any such application shall be applied
against (i) the Commitment of the Tranche A Lenders pro rata and/or (ii) the Tranche B Lenders pro rata. 

  

	6.10	Voluntary prepayment and cancellation 

  

	 	(a)	If the Borrower is, or will be, required to pay to a Lender a Tax Payment or an Increased Cost, the Borrower may, while the requirement continues, give notice to the Facility Agent
requesting prepayment and cancellation in respect of that Lender. 

  

	 	(b)	After notification under paragraph (a) above: 

  

	 	(i)	the Borrower must repay or prepay that Lender’s share in each Loan made to it on the date specified in paragraph (c) below; and 

  

	 	(ii)	the Commitment of that Lender will be immediately cancelled. 

  

	 	(c)	The date for repayment or prepayment of a Lender’s share in a Loan(s) will be the last day of the current Term for the relevant Loan or, if earlier, the date specified by the
Borrower in the notice delivered to the Facility Agent. 

  

					
	 	 	31	 	21 July 2005

	6.11	Partial prepayment of Loans 

  

	 	(a)	Except where this Clause 6 expressly provides otherwise, any partial prepayment of a Loan will be applied against the remaining Repayment Instalments in respect of that Loan, in the
inverse order of their maturity and shall be applied pro rata in respect of the amounts outstanding to the Tranche A Lenders and the Tranche B Lenders. 

  

	 	(b)	Upon any such partial prepayment, the Facility Agent shall replace the Repayment Schedule attached at Schedule 8 (Repayment Schedule) with a new Repayment Schedule reflecting the
correct Repayment Instalments and promptly provide a copy thereof to the Borrower. 

  

	 	(c)	No amount of a Loan prepaid under this Agreement may subsequently be re-borrowed 

  

	6.12	Miscellaneous provisions 

  

	 	(a)	Any notice of prepayment and/or cancellation under this Agreement is irrevocable and must specify the relevant date(s). 

  

	 	(b)	All prepayments under this Agreement must be made with accrued interest on the amount prepaid. All prepayments shall also be subject to Break Costs in respect of any amounts prepaid
to the Lenders. 

  

	 	(c)	No prepayment or cancellation is allowed except in accordance with the express terms of this Agreement. 

  

	7.	INTEREST 

  

	7.1	Calculation of interest 

  

	 	(a)	The rate of interest on each Loan for each Term is the percentage rate per annum equal to the aggregate of: 

  

	 	(i)	the Margin; 

  

	 	(ii)	LIBOR; and 

  

	 	(iii)	any increase in Mandatory Cost above the level of Mandatory Cost prevailing at the date of this Agreement (together, the Interest Rate). 

  

	 	(b)	Interest shall be calculated by reference to the actual number of days elapsed and on the basis of a year of 360 days. Interest shall accrue from and including the first day of each
Term to but excluding the last day of such Term. 

  

	7.2	Payment of interest 

  
 Except where it is provided to the contrary in this Agreement, the Borrower must pay accrued interest on each Loan on the last day of each Term.

  

	7.3	Interest on overdue amounts 

  

	 	(a)	If the Borrower fails to pay any amount payable by it under the Finance Documents, it must immediately on demand by the Facility Agent pay interest on the overdue amount from its
due date up to the date of actual payment, both before, on and after judgment. 

  

					
	 	 	32	 	21 July 2005

	 	(b)	If the overdue amount is a principal amount of a Loan or is an amount accruing in respect of interest on a Loan and becomes due and payable prior to the last day of its current
Term, then: 

  

	 	(i)	the first Term for that overdue amount will be the unexpired portion of that Term and the rate of interest on the overdue amount for that first Term will be two (2) per cent. per
annum above the Interest Rate; and 

  

	 	(ii)	thereafter, any subsequent Term for that overdue amount shall be selected by the Facility Agent (acting on the instructions of the Majority Lenders, acting reasonably) who may
select successive Terms of any duration up to six (6) months, and the rate of interest on the overdue amount will be two (2) per cent. per annum above the Interest Rate. 

  
 After the expiry of the first Term for that overdue amount, the rate on the overdue amount will be calculated in accordance
with paragraph (c) below. 
  

	 	(c)	In respect of any amounts outstanding other than in accordance with paragraph (b) above, interest on such overdue amount is payable at a rate determined by the Facility Agent to be
two (2) per cent. per annum above the Interest Rate. For this purpose, the Facility Agent may (acting on the instructions of the Majority Lenders, acting reasonably) select successive Terms of any duration of up to six (6) months.

  

	 	(d)	Interest (if unpaid) on an overdue amount will be compounded with that overdue amount at the end of each of its Terms but will remain immediately due and payable.

  

	7.4	Notification of rates of interest 

  
 The Facility Agent must promptly notify each Party of the determination of a rate of interest under this Agreement. 
  

	8.	TERMS 

  

	8.1	Selection 

  

	 	(a)	Each Loan has successive Terms. 

  

	 	(b)	The Borrower must select the first Term for a Loan in the relevant Request and each subsequent Term in an irrevocable notice received by the Facility Agent no later than 11.00 am
(New York time) three (3) Business Days before the Rate Fixing Day for that Term. Each Term for a Loan will start on its Utilisation Date or on the expiry of its preceding Term. If the Borrower fails to select a Term for an outstanding Loan under
this paragraph (b), that Term will, subject to the other provisions of this Clause, be three (3) months. 

  

	 	(c)	Subject to the following provisions of this Clause 8 and paragraph (b) above, each Term for a Loan shall be for a period of one (1), two (2), three (3) or six (6) months. When
making an election in respect of the Term of a Loan, the Borrower must make the same election in respect of all of the Loans then outstanding. 

  

	8.2	Consolidation 

  
 The first Term for the Drawing under a Loan will commence on its Utilisation Date and each subsequent Term shall commence on the last day of the previous
Term provided always that the first Term for the Drawings under the second and subsequent Loans shall end on the last day of the current Term for existing Drawings under the then existing Loan(s). 
  

					
	 	 	33	 	21 July 2005

	8.3	No overrunning the Final Maturity Date 

  
 If a Term would otherwise overrun the Final Maturity Date, it will be shortened so that it ends on the Final Maturity Date. 
  

	8.4	Other adjustments 

  
 The Facility Agent and the Borrower may enter into such other arrangements as they may agree for the adjustment of Terms and the consolidation and/or
splitting of Loans. 
  

	9.	MARKET DISRUPTION 

  

	9.1	Failure of the Reference Bank to supply a rate 

  
 If LIBOR is to be calculated by reference to the Reference Banks but if the Reference Banks are unable to supply a rate by 11.00 a.m. on the Rate Fixing
Day, the applicable LIBOR will be calculated in accordance with Clause 9.2 (Market disruption). 
  

	9.2	Market disruption 

  

	 	(a)	A market disruption event shall arise where: 

  

	 	(i)	no, or only one, Reference Bank supplies a rate by 11.00 a.m. on the Rate Fixing Day; or 

  

	 	(ii)	the Facility Agent receives by close of business on the Rate Fixing Day notification from any Lender or Lenders whose aggregate shares in the relevant Loan exceed 35 per cent. of
that Loan that the cost to them of obtaining matching deposits in the relevant interbank market is in excess of LIBOR for the relevant Term. 

  

	 	(b)	The Facility Agent must promptly notify the Borrower and the Lenders of a market disruption event. 

  

	 	(c)	After notification under paragraph (b) above, the rate of interest on the affected Loan for the relevant Term will be the aggregate of the applicable: 

  

	 	(i)	Margin; 

  

	 	(ii)	the rate notified to the Facility Agent by those Lenders as soon as practicable, and in any event before interest is due to be paid in respect of that Term, to be that which
expresses as a percentage rate per annum the cost to those Lenders of funding the Loan from whatever source each of them may reasonably select; and 

  

	 	(iii)	any increase in Mandatory Cost above the level of Mandatory Cost prevailing at the date of this Agreement. 

  

	9.3	Alternative basis of interest or funding 

  

	 	(a)	If a market disruption event occurs and the Facility Agent or the Borrower so require, the Borrower and the Facility Agent must enter into negotiations for a period of not more than
thirty (30) days with a view to agreeing to an alternative basis for determining the rate of interest and/or funding for the affected Loan and any future Loan. 

  

					
	 	 	34	 	21 July 2005

	 	(b)	Any alternative basis agreed between the Borrower and the Facility Agent will be, with the prior written consent of all the Lenders, binding on all the Parties hereto.

  

	10.	TAXES 

  

	10.1	Tax gross-up 

  

	 	(a)	The Borrower must make all payments to be made by it under the Finance Documents without any Tax Deduction, unless a Tax Deduction is required by an Applicable Law.

  

	 	(b)	If a Tax Deduction is required by an Applicable Law to be made by the Borrower or, as the case may be, the Facility Agent, the amount of the payment due from the Borrower will be
increased, or, as the case may be, the Borrower shall make an additional payment, so that the amount (after making the Tax Deduction) received by the recipient is equal to the payment which would have been due if no Tax Deduction had been required.

  

	 	(c)	If the Borrower is required to make a Tax Deduction, the Borrower must make the minimum Tax Deduction and must make any payment required in connection with that Tax Deduction within
the time allowed by the Applicable Law. 

  

	 	(d)	Within fifteen (15) days of making either a Tax Deduction or a payment required in connection with a Tax Deduction the Borrower must deliver to the Facility Agent for the relevant
Finance Party, documents or other information (or certified copies thereof) evidencing satisfactorily to that Finance Party (acting reasonably) that the Tax Deduction has been made or (as applicable) the appropriate payment has been paid to the
relevant taxing authority. 

  

	10.2	Tax Indemnity 

  
 Without prejudice to the provisions of Clause 10.1 (Tax gross-up), if any Lender is required to make any payment on account of Tax solely as a result of
its entry into any Finance Document (not being a Tax imposed on the net income of a Lender or its Facility Office by the jurisdiction in which it is incorporated, or the jurisdiction in which its Facility Office is located or on the capital of that
Lender employed in such jurisdiction or jurisdictions) on any sum received or receivable under the Finance Documents (including, without limitation, any sum received or receivable under this Clause 10.2) or any liability in respect of any such
payment is asserted, imposed, levied or assessed against a Lender, the Borrower shall (within three (3) Business Days of demand by the Facility Agent) indemnify that Lender against such payment or liability, together with any interest, penalties and
expenses payable or incurred in connection therewith. 
  

	10.3	Tax Credit 

  
 If a Lender or, as the case may be, the Facility Agent determines in its absolute discretion, acting in good faith, that it has received, realised,
utilised and retained a Tax benefit by reason of any deduction or withholding in respect of which the Borrower has made an increased payment or paid a compensating sum under this Clause 10 that Lender or, as the case may be, the Facility Agent
shall, provided it has received all amounts which are then due and payable by the Borrower under any of the provisions of this Agreement and the other Finance Documents, pay to the Borrower (to the extent that that Lender or, as the case may be, the
Facility Agent can do so without prejudicing the amount of that benefit and the right of that Lender, or as the case may be, the Facility Agent to obtain any other benefit, relief or allowance which may be available to it), such amount, if any, as
that Lender, or as the case may be, the Facility Agent shall determine in its absolute discretion acting in good faith, will leave that Lender, or as the case may be, the Facility Agent in no better and no worse position than it would have been in
if the deduction or withholding had not been required and so that it retains no benefit as a result of the receipt of such deduction. 
  

					
	 	 	35	 	21 July 2005

	10.4	Confidentiality of Tax Affairs 

  
 A Lender making, or intending to make, a claim under Clause 10.2 (Tax Indemnity) shall promptly notify the Facility Agent of the event which will give, or
has given, rise to the claim, following which the Facility Agent shall notify the Borrower. 
  

	10.5	Conduct of Business by the Finance Parties 

  
 No provision of this Agreement will: 
  

	 	(a)	Interfere with the right of any Finance Party to arrange its affairs (tax or otherwise) in whatever manner it thinks fit; 

  

	 	(b)	Oblige any Finance Party to investigate or claim any credit, relief, remission or repayment available to it or the extent, order and manner of any claim; or

  

	 	(c)	Oblige any Finance Party to disclose any information relating to its affairs (tax or otherwise) or any computations in respect of Tax. 

  

	10.6	Stamp taxes 

  
 The Borrower must pay and indemnify each Finance Party against any stamp duty, registration or other similar Tax payable by a Finance Party in connection
with the entry into, performance or enforcement of any Finance Document, except for any such Tax payable in connection with entering into a Transfer Certificate. 
  

	10.7	Value added taxes 

  
 Any amount (including costs and expenses) payable under a Finance Document by the Borrower is exclusive of any value added tax or any other Tax of a
similar nature which might be chargeable in connection with that amount. If any such Tax is chargeable, the Borrower must pay to the relevant Finance Party (in addition to and at the same time as paying that amount) an amount equal to the amount of
that Tax. 
  

	11.	INCREASED COSTS 

  

	11.1	Increased Costs 

  
 Except as provided below in this Clause 11, the Borrower must pay to a Finance Party the amount of any Increased Cost incurred by that Finance Party or
its Subsidiaries, or its Affiliates as a result of: 
  

	 	(a)	the introduction of, or any change in, or any change in the interpretation or application of, any law or regulation; or 

  

	 	(b)	compliance with any law or regulation, 

  
 made after the date of this Agreement. 
  

	11.2	Exceptions 

  
 The Borrower need not make any payment for an Increased Cost to the extent that the Increased Cost is: 
  

	 	(a)	compensated for under another Clause or would have been but for an exception to that Clause; 

  

					
	 	 	36	 	21 July 2005

	 	(b)	a Tax on the overall net income of the relevant Finance Party or any of its Subsidiaries; or 

  

	 	(c)	attributable to the relevant Finance Party or any of its Subsidiaries wilfully failing to comply with any law or regulation. 

  

	11.3	Claims 

  
 If a Finance Party intends to make a claim for an Increased Cost it must notify the Borrower promptly of the circumstances giving rise to, and the amount
of, the claim. 
  

	11.4	Mitigation 

  

	 	(a)	Each Finance Party must, in consultation with the Borrower, use its best endeavours to mitigate any circumstances which arise and which result or would result in any Increased Cost
being payable to that Finance Party. 

  

	 	(b)	The Borrower must indemnify that Finance Party for all costs and expenses reasonably incurred by that Finance Party as a result of any step taken by it under paragraph (a) above.

  

	 	(c)	A Finance Party is not obliged to take any step under this Subclause if, in the opinion of that Finance Party (acting reasonably), to do so might be prejudicial to it.

  

	11.5	Replacement of Lender 

  
 Following a claim by a Lender for an Increased Cost, the Borrower shall, with the consent of the Facility Agent (acting on the instructions of the
Majority Lenders), be entitled to oblige such Lender to transfer its Commitment to a new lender pursuant to the terms of Clause 28 (Changes to the Parties). 
  

	12.	RETENTION ACCOUNT 

  

	12.1	Maintenance of Retention Account 

  
 The Borrower shall maintain the Retention Account with the Account Bank until the Final Maturity Date, free of Security Interests and rights of set-off
other than as created by or pursuant to the Security Documents. 
  

	12.2	Transfers to Retention Account 

  

	 	(a)	The Borrower shall procure that upon receipt of any amounts representing proceeds of a sale of a Vessel or proceeds following a Total Loss of a Vessel or proceeds following the
termination of a Time Charter, such amounts are paid into the Retention Account. 

  

	 	(b)	Upon the occurrence of an Event of Default which is continuing, the Borrower shall procure that all Earnings in respect of the Vessels are transferred into the Retention Account.

  

	12.3	Application of Retention Account 

  

	 	(a)	 In the event that a mandatory prepayment obligation arises under Clause 6.5(a) upon a sale or Total Loss of a Vessel, the Borrower shall procure that there is
transferred from the Retention Account (and irrevocably authorises the Facility Agent to instruct the Account 

  

					
	 	 	37	 	21 July 2005

 
Bank to transfer from the Retention Account) to the Facility Agent in prepayment of the relevant Loan: 
  

	 	(i)	an amount equal to the proportion that the Initial Market Value of the Vessel the subject of the sale or Total Loss bears to the aggregate Initial Market Value of the Vessels
actually delivered; and 

  

	 	(ii)	any amounts as may be required pursuant to Clause 6.5(b) to ensure that the relevant Required Amount is satisfied, 

  
 and (unless an Event of Default shall have occurred and be continuing) the
balance of the proceeds of a sale or Total Loss of the relevant Vessel, following the transfers in paragraphs (i) and (ii) above, may be released to such other account as the Borrower shall designate. 
  

	 	(b)	In the event that a charter termination event arises under Clause 16.24(b) (Termination of Time Charter), the Borrower shall procure that there is transferred from the Retention
Account (and irrevocably authorises the Facility Agent to instruct the Account Bank to transfer from the Retention Account): 

  

	 	(i)	if the Borrower locates a substitute charterer in accordance with Clause 16.24(c) or (d), to such other account as the Borrower may designate, the charter termination amount
relating to the relevant Vessel; or 

  

	 	(ii)	if a mandatory prepayment obligation arises under Clause 6.4(b), to the Facility Agent in prepayment of the relevant Loan an amount necessary to ensure that the Loan to Value Ratio
in respect of such Vessel is no greater than 60 per cent. 

  

	 	(c)	Following the occurrence of an Event of Default which is continuing, any moneys standing to the credit of the Retention Account shall be applied in accordance with Clause 13.7
(Payments). 

  

	12.4	Restriction on withdrawal 

  
 During the term of the Facility, no sum may be withdrawn from the Retention Account t (except in accordance with this Clause 12) without the prior written
consent of the Facility Agent (acting on the instructions of the Majority Lenders). 
  

	13.	PAYMENTS 

  

	13.1	Place 

  

	 	(a)	Unless a Finance Document specifies that payments under it are to be made in another manner, all payments by a Party (other than the Facility Agent) under the Finance Documents must
be made to the Facility Agent to its account no. [0011624418 with J P Morgan Chase, New York, ABA No. 021 000 021] for the credit of Fortis Capital Corp. or such other account in the United States of America as it may notify to that Party for this
purpose by not less than five (5) Business Days’ prior notice. 

  

	 	(b)	Notwithstanding paragraph (a) above, any payment to be made under the Finance Documents by the Facility Agent to a Lender shall be made in accordance with that Lender’s
Standing Payment Instruction. 

  

					
	 	 	38	 	21 July 2005

	13.2	Funds 

  
 Payments under the Finance Documents to the Facility Agent must be made for value on the due date at such times and in such funds as the Facility Agent
may specify to the Party concerned as being customary at the time for the settlement of transactions in the relevant currency in the place for payment. 
  

	13.3	Distribution 

  

	 	(a)	Each payment received by the Facility Agent under the Finance Documents for another Party must, except as provided below, be made available by the Facility Agent to that Party by
payment (as soon as practicable after receipt) to its account with such office or bank as it may notify to the Facility Agent for this purpose by not less than five (5) Business Days’ prior notice. 

  

	 	(b)	The Facility Agent may apply any amount received by it from the Borrower in or towards payment (on the date and in the currency and funds of receipt) of any amount due from the
Borrower under the Finance Documents or in or towards the purchase of any amount of any currency to be so applied. 

  

	 	(c)	Where a sum is paid to the Facility Agent under this Agreement for another Party, the Facility Agent is not obliged to pay that sum to that Party until it has established that it
has actually received it. However, the Facility Agent may assume that the sum has been paid to it, and, in reliance on that assumption, make available to that Party a corresponding amount. If it transpires that the sum has not been received by the
Facility Agent, that Party must immediately on demand by the Facility Agent refund any corresponding amount made available to it together with interest on that amount from the date of payment to the date of receipt by the Facility Agent at a rate
calculated by the Facility Agent to reflect its cost of funds. 

  

	 	(d)	For the purposes of this Clause 13 (Payments) Standing Payment Instruction means: 

  

	 	(i)	in relation to a Lender which is a Lender on the date of this Agreement, payment instructions set below the name of that Lender in Schedule 12 (Standing Payment Instructions); or

  

	 	(ii)	in relation to a Lender which becomes a Lender after the date of this Agreement, payment instructions set out in the Transfer Certificate to which that Lender is a party,

  
 or such other payment instructions the Lender
may notify to the Facility Agent by not less than five (5) Business Days’ notice. 
  

	13.4	Currency 

  
 All amounts payable under the Finance Documents are payable in Dollars provided always that amounts payable in respect of costs and expenses are payable
in the currency in which those costs and expenses are incurred. 
  

	13.5	No set-off or counterclaim 

  
 All payments made by the Borrower under the Finance Documents must be made without set-off or counterclaim. 
  

					
	 	 	39	 	21 July 2005

	13.6	Business Days 

  

	 	(a)	If a payment under the Finance Documents is due on a day which is not a Business Day, the due date for that payment will instead be the next Business Day in the same calendar month
(if there is one) or the preceding Business Day (if there is not). 

  

	 	(b)	During any extension of the due date for payment of any principal under this Agreement interest is payable on that principal at the rate payable on the original due date.

  

	13.7	Payments 

  

	 	(a)	Subject always to the provisions of the DPP, if any Administrative Party receives a payment insufficient to discharge all the amounts then due and payable by the Borrower under the
Finance Documents, then, except to the extent otherwise provided in any Finance Document, all the proceeds of the enforcement of the security conferred by the Security Agreements shall be applied by the Administrative Party towards the obligations
of the Borrower under the Finance Documents in the following order: 

  

	 	(i)	first, in or towards payment or satisfaction pro rata of all costs, charges, sales taxes, expenses and liabilities incurred and payments made by the Finance Parties
(other than the Swap Counterparties) or any receiver and all remuneration payable to the Finance Parties (other than the Swap Counterparties) or any receiver under or pursuant to the Security Documents including, without limitation, legal expenses,
re-instatement costs and any costs incurred in recovering possession of the Security Assets; 

  

	 	(ii)	second, in or towards payment pro rata of any unpaid fees, costs and expenses of the Finance Parties (other than the Swap Counterparties) to the extent not recovered
under paragraph (i) above under this Agreement and the Security Documents; 

  

	 	(iii)	third, in or towards payment pro rata of any accrued but unpaid interest payable to the Finance Parties (other than the Swap Counterparties) under this Agreement and
the Security Documents; 

  

	 	(iv)	fourth, in or towards payment pro rata of any Break Costs of the Lenders due but unpaid and payable to the Finance Parties (other than the Swap Counterparties) under
this Agreement and the Security Documents; 

  

	 	(v)	fifth, in or towards payment pro rata of any principal in respect of this Agreement and the Security Documents due but unpaid; 

  

	 	(vi)	sixth, in or towards payment pro rata to the Finance Parties (other than the Swap Counterparties) of any other amounts which are due but unpaid by the Borrower to any
of the Finance Parties (other than the Swap Counterparties) under the Finance Documents in such order as the Finance Parties (other than the Swap Counterparties) shall in their absolute discretion determine; 

  

	 	(vii)	seventh, in or towards payment of any unpaid interest, fees, costs and expenses of the Swap Counterparties under the Swap Agreements and the Swap Mortgages;

  

	 	(viii)	eighth, in or towards payment of any Break Costs of the Swap Counterparties due but unpaid under the Swap Agreements; 

  

					
	 	 	40	 	21 July 2005

	 	(ix)	ninth, in or towards payment to the Swap Counterparties of any other amounts which are or may become owing by any of the Borrower to any of the Swap Counterparties under the
Swap Agreement; 

  

	 	(x)	tenth, after all amounts payable or which may become payable under the Finance Documents have been paid in full and the Finance Documents have been discharged and the
payments under subparagraph (x) have been made, in or towards payment of the surplus if any, to the Borrower or other persons entitled thereto. 

  

	 	(b)	The Facility Agent must, if so directed by all the Lenders, vary the order set at subparagraphs 13.7(a)(ii) to 13.7(a)(vi) above. 

  

	 	(c)	This Clause 13.7 will override any appropriation made by the Borrower. 

  

	13.8	Timing of payments 

  
 If a Finance Document does not provide for when a particular payment is due, that payment will be due within three (3) Business Days of demand by the
relevant Finance Party. 
  

	14.	REPRESENTATIONS 

  

	14.1	Representations 

  
 The representations set out in this Clause 14 are made, unless otherwise stated, by the Borrower to the Finance Parties. 
  

	14.2	Status 

  

	 	(a)	It is a limited liability company, duly incorporated and validly existing under the laws of [the Republic of the Marshall Islands]. 

  

	 	(b)	It and each of its Subsidiaries, if any, has the power to own its assets and carry on its business as it is being conducted. 

  

	 	(c)	It is wholly owned by the Shareholder other than following an IPO, and at all times following an IPO, no person or group other than the Seaspan Group will beneficially own more than
fifty (50) per cent. of the aggregate outstanding voting power of the equity interests of the Borrower. 

  

	14.3	Powers and authority 

  
 It has the power to enter into and perform, and has taken all necessary action to authorise the entry into and performance of, the Finance Documents to
which it is or will be a party and the transactions contemplated by those Finance Documents. 
  

	14.4	Legal validity 

  
 Subject to any general principles of law limiting its obligations and referred to in any legal opinion required under this Agreement, each Finance
Document to which it is a party is its legally binding, valid and enforceable obligation. 
  

	14.5	Non-conflict 

  
 The entry into and performance by it of, and the transactions contemplated by, the Finance Documents to which it is a party do not conflict in any
material respect with: 
  

	 	(a)	any law or regulation applicable to it; 

  

					
	 	 	41	 	21 July 2005

	 	(b)	its or any of its Subsidiaries’ constitutional documents; or 

  

	 	(c)	any document which is binding upon it or any of its Subsidiaries or any of its or its Subsidiaries’ assets. 

  

	14.6	No Default 

  

	 	(a)	No Default is outstanding or will result from the execution of, or the performance of any transaction contemplated by, any Finance Document. 

  

	 	(b)	No other event is outstanding which constitutes a default under any document which is binding on it or any of its Subsidiaries or any of its or its Subsidiaries’ assets to an
extent or in a manner which is reasonably likely to have a Material Adverse Effect. 

  

	14.7	Authorisations 

  
 Except for registration of (i) the Mortgages at the [Hong Kong Shipping Register], (ii) any Security Agreement creating a charge over Security Assets of
the Borrower with the [Hong Kong Registrar of Companies] or (iii) any relevant Security Agreement under the Companies Act 1985, all authorisations required by it in connection with the entry into, performance, validity and enforceability of, and the
transactions contemplated by, the Finance Documents have been obtained or effected (as appropriate) and are in full force and effect. 
  

	14.8	Financial statements 

  
 The audited consolidated financial statements of the Borrower most recently delivered to the Facility Agent (or, until delivery of the first audited
financial statements, the Original Balance Sheet) together with any other financial information supplied to the Facility Agent by the Borrower: 
  

	 	(a)	have been prepared in accordance with U.S. GAAP, consistently applied; 

  

	 	(b)	have been audited in accordance with international accounting standards; and 

  

	 	(c)	fairly represent its financial condition (consolidated, if applicable) as at the date to which they were drawn up, 

  
 except, in each case, as disclosed to the contrary in those financial
statements or other information. 
  

	14.9	No material adverse change 

  
 There has been no material adverse change in the ability of the Borrower to make all the required payments under this Agreement or the validity or
enforceability of this Agreement since the date of incorporation of the Borrower or following the receipt by the Facility Agent of an Annual Compliance Certificate, since the date of the then latest Annual Compliance Certificate. 
  

	14.10	Litigation 

  
 No litigation, arbitration or administrative proceedings of or before any court, arbitral body or agency (including, but not limited to, investigative
proceedings) which, if adversely determined, might reasonably be expected to have a Material Adverse Effect have (to the best of its knowledge and belief) been started or threatened against the Borrower. 
  

					
	 	 	42	 	21 July 2005

	14.11	Pari passu ranking 

  
 Its payment obligations under the Finance Documents rank at least pari passu with all its other present and future unsecured and unsubordinated
payment obligations, except for obligations mandatorily preferred by law applying to companies generally. 
  

	14.12	Taxes on payments 

  
 All amounts payable by it to the Facility Agent under the Finance Documents and the Related Contracts may be made without any Tax Deduction. 

 

	14.13	Stamp duties 

  
 Except as notified in writing to and accepted by the Facility Agent, no stamp or registration duty or similar Tax or charge is payable in its jurisdiction
of incorporation in respect of any Finance Document or Related Contract. 
  

	14.14	Environment 

  
 Except as may already have been disclosed by the Borrower in writing to the Facility Agent: 
  

	 	(a)	the Borrower and its Environmental Affiliates have, without limitation, complied with the provisions of all applicable Environmental Laws in relation to each Vessel;

  

	 	(b)	the Borrower and its Environmental Affiliates have obtained all requisite Environmental Approvals in relation to each Vessel and are in compliance with such Environmental Approvals;

  

	 	(c)	neither the Borrower nor any of its Environmental Affiliates have received notice of any Environmental Claim in relation to the relevant Vessel which alleges that the Borrower is
not in compliance with applicable Environmental Laws in relation to such Vessel or Environmental Approvals in relation to such Vessel; 

  

	 	(d)	there is no Environmental Claim in relation to any Vessel pending or threatened which is such that a first class Borrower or operator of vessels such as the Vessels, making all due
enquiries and complying in all respects with its obligations under the ISM Code, ought to have known about; and 

  

	 	(e)	there has been no Release of Hazardous Materials by or in respect of any Vessel about which a first class Borrower or operator of vessels such as the Vessels making all due
enquiries and complying in all respects with its obligations under the ISM Code ought to have known about. 

  

	14.15	Security Interests 

  
 No Security Interest exists over its or any of its Subsidiary’s assets which would cause a breach of Clause 16.5 (Security Interests). 
  

	14.16	Security Assets 

  
 The Borrower is solely and absolutely entitled to the Security Assets over which it has or will create any Security Interest pursuant to the Security
Documents to which it is, or will be, a party and there is no agreement or arrangement, other than in the DPP, under which it is obliged to share any proceeds of or derived from such Security Assets with any third party. 
  

					
	 	 	43	 	21 July 2005

	14.17	ISM Code compliance 

  
 In respect of the Delivered Vessels, on the date of the first Drawing under the Delivered Vessels Loan or, in respect of the Subsequent Vessels and any
Additional Vessel, on the Delivery Date in respect of that Vessel, the Borrower is in full compliance with the ISM Code in respect of its Vessel. 
  

	14.18	ISPS Code Compliance 

  
 In respect of the Delivered Vessels, on the date of the first Drawing under the Delivered Vessels Loan or, in respect of the Subsequent Vessels and any
Additional Vessel, on the Delivery Date in respect of that Vessel, the Borrower is in full compliance with the ISPS Code in respect of its Vessel. 
  

	14.19	No amendments to Related Contracts 

  
 Other than as notified to and agreed by the Facility Agent in writing, there have been no amendments to any of the Related Contracts. 
  

	14.20	Money Laundering 

  
 Any borrowing by the Borrower and the performance of its obligations hereunder and under the other Finance Documents to which it is a party will be for
its own account and will not involve any breach by it of any law or regulatory measure relating to money laundering as defined in Article 1 of the Directive (91/308/EEC) of the Council of the European Communities or any equivalent law or regulatory
measure in any other jurisdiction. 
  

	14.21	Insolvency 

  

	 	(a)	The Borrower is neither unable, nor admits or has admitted its inability, to pay its debts or has suspended making payments on any of its debts. 

  

	 	(b)	The Borrower, by reason of actual or anticipated financial difficulties neither has commenced, nor intends to commence, negotiations with one or more of its creditors with a view to
rescheduling any of its Financial Indebtedness. 

  

	 	(c)	The value of the assets of the Borrower is not less than its liabilities (taking into account contingent and prospective liabilities). 

  

	 	(d)	No moratorium has been, or may, in the reasonably foreseeable future be, declared in respect of any indebtedness of the Borrower. 

  

	14.22	Immunity 

  

	 	(a)	The execution by it of each Finance Document to which it is a party constitutes, and the exercise by it of its rights and performance of its obligations under each such Finance
Document will constitute, private and commercial acts performed for private and commercial purposes. 

  

	 	(b)	It will not be entitled to claim immunity from suit, execution, attachment or other legal process in any proceedings taken in its jurisdiction of incorporation in relation to any
Finance Document. 

  

	14.23	No adverse consequences 

  

	 	(a)	It is not necessary under the laws of its jurisdiction of incorporation: 

  

	 	(i)	in order to enable the Facility Agent to enforce its rights under any Finance Document; or 

  

					
	 	 	44	 	21 July 2005

	 	(ii)	by reason of the execution of any Finance Document or the performance by it of its obligations under any Finance Document, 

  
 that the Facility Agent should be licensed, qualified or otherwise entitled
to carry on business in its jurisdiction of incorporation; and 
  

	 	(b)	The Facility Agent will not be deemed to be resident, domiciled or carrying on business in its jurisdiction of incorporation by reason only of the execution, performance and/or
enforcement of any Finance Document. 

  

	14.24	Jurisdiction/governing law 

  

	 	(a)	Its: 

  

	 	(i)	irrevocable submission under this Agreement to the jurisdiction of the courts of England; 

  

	 	(ii)	agreement that this Agreement is governed by English law; and 

  

	 	(iii)	agreement not to claim any immunity to which it or its assets may be entitled, 

  
 are legal, valid and binding under the laws of its jurisdiction of incorporation. 
  

	 	(b)	Any judgment obtained in England will be recognised and be enforceable by the courts of its jurisdiction of incorporation, subject to any statutory or other conditions of such
jurisdiction. 

  

	14.25	Charters 

  
 In respect of the Delivered Vessels, on the date of the first Drawing under the Delivered Vessels Loan or, in respect of the Subsequent Vessels and any
Additional Vessel, on the date of the first Drawing under the Loan relating to such Vessel, any Time Charter in respect of that Vessel shall be in full force and effect. 
  

	14.26	Times for making representations 

  

	 	(a)	The representations set out in this Clause 14 are made by the Borrower on the date of this Agreement. 

  

	 	(b)	Unless a representation is expressed to be given at a specific date, each representation is deemed to be repeated by the Borrower on the date of each Request, the date of each
Drawing under a Loan and annually on each anniversary of the first Utilisation Date when the Borrower shall provide to the Facility Agent an Annual Compliance Certificate. 

  

	 	(c)	When a representation is repeated, it is applied to the circumstances existing at the time of repetition. 

  

	15.	INFORMATION COVENANTS 

  

	15.1	Financial statements 

  

	 	(a)	The Borrower must supply to the Facility Agent in sufficient copies (which may take the form of an electronic copy) for all the Lenders: 

  

	 	(i)	its audited consolidated financial statements for each of its financial years ending after the date hereof; 

  

					
	 	 	45	 	21 July 2005

	 	(ii)	its interim unaudited financial statements for the first half-year of each of its financial years; and 

  

	 	(iii)	if and to the extent the Borrower is required by any Applicable Law to produce quarterly financial statements, the quarterly financial statements for the Borrower as the case may be
for the first and third quarters of each of its financial years ending after the date hereof. 

  

	 	(b)	The Borrower must supply to the Facility Agent copies of the audited financial statements of each Charterer for each of the relevant Charterer’s financial years within two (2)
Business Days of such financial statements becoming available. 

  

	 	(c)	All financial statements must be supplied promptly after they are available and: 

  

	 	(i)	in the case of audited financial statements of the Borrower, within 180 days of the end of the relevant financial period; 

  

	 	(ii)	in the case of interim semi-annual financial statements of the Borrower, within ninety (90) days of the end of the relevant financial period; and 

  

	 	(iii)	in the case of interim quarterly financial statements of the Borrower, within sixty (60) days of the end of the relevant financial period. 

  

	 	(d)	The Facility Agent shall send to each Lender all of the financial statements received by it under this Clause 15.1 within fifteen (15) days of receipt of such financial statements.

  

	15.2	Form of financial statements 

  

	 	(a)	The Borrower must ensure that each set of its financial statements supplied under this Agreement fairly represents the financial condition (consolidated or otherwise) of the
Borrower as at the date to which those financial statements were drawn up. 

  

	 	(b)	The Borrower must notify the Facility Agent of any change to the basis on which its audited financial statements are prepared. 

  

	 	(c)	If requested by the Facility Agent, the Borrower must supply or procure that the following are supplied to the Facility Agent: 

  

	 	(i)	a full description of any change notified under paragraph (b) above; and 

  

	 	(ii)	sufficient information to enable the Facility Agent to make a proper comparison between the financial position shown by the set of financial statements prepared on the changed basis
and its most recent audited consolidated financial statements delivered to the Facility Agent under this Agreement. 

  

	 	(d)	If requested by the Facility Agent, the Borrower must enter into discussions for a period of not more than thirty (30) days with a view to agreeing to any amendments required to be
made to this Agreement to place the Facility Agent in the same position as it would have been in if the change had not happened. 

  

					
	 	 	46	 	21 July 2005

	 	(e)	If no agreement is reached under paragraph (d) above on the required amendments to this Agreement, the Borrower must ensure that its auditors certify those amendments; the
certificate of the auditors will be, in the absence of manifest error, binding on all the Parties. 

  

	15.3	Compliance Certificate 

  

	 	(a)	The Borrower must supply to the Facility Agent a Compliance Certificate in the form attached at Schedule 8 on a quarterly basis (the first such Compliance Certificate to be provided
on the first Quarter Day following the date of the first drawdown under the Facility). 

  

	 	(b)	The Borrower must supply to the Facility Agent an Annual Compliance Certificate in the form attached at Schedule 9 with each set of its financial statements sent to the Facility
Agent under this Agreement. 

  

	 	(c)	Each Compliance Certificate supplied by the Borrower must be signed by its chief financial officer or chief executive officer. 

  

	15.4	Access to Books and Records 

  
 Upon the request of the Facility Agent, the Borrower shall provide the Facility Agent and any of its representatives, professional advisors and
contractors with access to, and permit inspection of, its books and records, in each case at reasonable times and upon reasonable notice. 
  

	15.5	Information - miscellaneous 

  
 The Borrower must supply to the Facility Agent in sufficient copies (which may take the form of an electronic copy) for all the Lenders: 
  

	 	(a)	copies of all documents despatched by it to its creditors generally or any class of them at the same time as they are despatched; 

  

	 	(b)	copies of all notices and minutes relating to any Extraordinary General Meeting of its shareholders at the same time as they are despatched; 

  

	 	(c)	promptly upon becoming aware of them, details of any litigation, arbitration or administrative proceedings which are current, threatened or pending against it and which might, if
adversely determined, have a Material Adverse Effect; and 

  

	 	(d)	promptly on request, such further information, in sufficient copies for all the Lenders, regarding the financial condition and operations of the Borrower as the Facility Agent may
reasonably request. 

  

	15.6	Notification of Default 

  

	 	(a)	Unless the Facility Agent has already been so notified, the Borrower must notify the Facility Agent of any Default (and the steps, if any, being taken to remedy it) promptly upon
becoming aware of its occurrence. 

  

	 	(b)	Promptly on request by the Facility Agent but not more often than once in each period of 12 months, unless the Facility Agent, acting reasonably, believes an Event of Default has
occurred and is continuing (in which event the Facility Agent shall be entitled to make such requests as and when it considers it appropriate to do so), the Borrower must supply to the Facility Agent a certificate, signed by two of its authorised
signatories on its behalf, certifying that no Default is outstanding or, if a Default is outstanding, specifying the Default and the steps, if any, being taken to remedy it. 

  

					
	 	 	47	 	21 July 2005

	15.7	Year end 

  
 The Borrower may not change its financial year end. 
  

	16.	GENERAL COVENANTS 

  

	16.1	General 

  
 The Borrower agrees to be bound by the covenants set out in this Clause 16 relating to it. 
  

	16.2	Authorisations 

  
 The Borrower must promptly obtain, maintain and comply, in all material respects, with the terms of any authorisation required under any Applicable Law to
enable it to perform its obligations under, or for the validity or enforceability of, any Finance Document. 
  

	16.3	Compliance with laws 

  
 The Borrower must comply and must procure that each Manager complies in all respects with all Applicable Laws to which it is subject where failure to do
so is reasonably likely to have a Material Adverse Effect. 
  

	16.4	Pari passu ranking 

  
 The Borrower must ensure that its payment obligations under the Finance Documents rank at least pari passu with all its other present and future
unsecured payment obligations, except for obligations mandatorily preferred by law applying to companies generally. 
  

	16.5	Security Interests 

  
 The Borrower shall not, and the Borrower shall procure that each Manager does not, create or permit to subsist any Security Interest over the Obligatory
Insurances or any other Security Assets or any Related Contract other than: 
  

	 	(a)	Permitted Liens; or 

  

	 	(b)	with the prior written consent of the Facility Agent (acting on the instructions of the Majority Lenders). 

  

	16.6	No other business assets or Financial Indebtedness 

  
 The Borrower shall not engage in any business other than the direct or indirect ownership, operation and chartering of container vessels, or any business
incidental thereto, nor shall the Borrower incur any Financial Indebtedness to be secured in any way on the Vessels, or any of them, or any other Security Asset other than the Financial Indebtedness contemplated by this Agreement or the Swap
Agreements. The Borrower may incur any other indebtedness or issue guarantees against financial loss of any person on an unsecured basis or secured on assets which are not, and will not at any time be, Security Assets provided that if the Borrower
intends to incur such other indebtedness in connection with the acquisition of container vessels, the Borrower shall first provide the Lenders with a right of first refusal to finance such acquisition through initiation of the Tranche B Commitments
before seeking any additional indebtedness contemplated by this Clause 16.6. 
  

					
	 	 	48	 	21 July 2005

	16.7	Payment of dividends 

  
 The Borrower shall not pay any dividends or make any other distributions (whether by loan or otherwise) to shareholders unless, under Applicable Law and
accounting principles in its jurisdiction of incorporation it is entitled to distribute as dividends or such other distribution and no Event of Default has occurred and is continuing. 
  

	16.8	Change of business 

  

	 	(a)	The Borrower must ensure that no change is made to the general nature of its business from that carried on at the date of this Agreement other than the direct or indirect ownership,
operation and chartering of container vessels, or any business incidental thereto. 

  

	 	(b)	The Borrower must maintain its place of business, and keep its corporate documents and records, at the address stated opposite its name in Schedule 1 (Original Parties), and the
Borrower will not establish, or do anything as a result of which it would be deemed to have, a place of business in any country other than the Republic of the Marshall Islands[, provided that the Borrower may establish a place of business in either
Hong Kong or Vancouver if the Facility Agent (acting on the instructions of the Majority Lenders) is satisfied that such establishment in such location does not adversely affect the validity, enforceability or effectiveness of any Security Agreement
and does not give rise to any requirement under any Applicable Law for a Tax Deduction]. 

  

	16.9	Mergers 

  
 The Borrower shall not enter into any amalgamation, demerger, merger or reconstruction otherwise than under an intra-group re-organisation on a solvent
basis or other transaction agreed by the Facility Agent. 
  

	16.10	Security 

  
 The Borrower: 
  

	 	(a)	will procure, at the Applicable Time, that the relevant Mortgage is, and continues to be, registered as a first priority mortgage on the [Hong Kong Shipping Register];

  

	 	(b)	without prejudice to paragraph (a) will procure that the Mortgages and any other security conferred by it under any Security Document are registered as a first priority interest
with the relevant authorities within the period prescribed by the Applicable Laws and is maintained and perfected with the relevant authorities; 

  

	 	(c)	will at its own cost, use best efforts to ensure that any Finance Document validly creates the obligations and Security Interests which it purports to create; and

  

	 	(d)	without limiting the generality of paragraph (a) above, will at its own cost, promptly register, file, record or enrol any Finance Document with any court or authority, pay any
stamp, registration or similar tax payable in respect of any Finance Document, give any notice or take any other step which, in the reasonable opinion of the Facility Agent, is or has become necessary or desirable for any Finance Document to be
valid, enforceable or admissible in evidence or to ensure or protect the priority of any Security Interest which it creates. 

  

					
	 	 	49	 	21 July 2005

	16.11	Registration of the Vessels 

  
 The Borrower shall and procure that the Manager shall: 
  

	 	(a)	procure and maintain with effect from, the Applicable Time, the valid and effective provisional registration of the Vessel under the flag of [Hong Kong] and shall effect permanent
registration of the Vessel within two months from the Applicable Time, or such other flag of equivalent reputation as is satisfactory to the Facility Agent (such approval not to be unreasonably withheld), and shall ensure nothing is done or omitted
by which the registration of the Vessels would or might be defeated or imperilled; and 

  

	 	(b)	not change the name or port of registration of the Vessels without the prior written consent of the Facility Agent (acting on the instructions of the Majority Lenders) (such consent
not to be unreasonably withheld). 

  

	16.12	Partial prepayments or additional security 

  

	 	(a)	The Borrower will not permit the aggregate Market Value of the delivered Vessels from time to time to be less than the Required Amount, such test to be determined no more than
semi-annually as provided in Clause 16.12(c) below. 

  

	 	(b)	If and so often as the aggregate Market Value of the delivered Vessels shall be less than the Required Amount, the Borrower will, within thirty (30) days of the request of the
Facility Agent to do so, either (i) prepay such amount of the Loans as will ensure that the aggregate Market Value of the delivered Vessels is not less than the Required Amount; or (ii) provide or cause to be provided to the Facility Agent such
additional security, in all respects satisfactory to the Facility Agent (acting on the instructions of the Majority Lenders), such that the Required Amount is again met. For the purposes of determining whether the Required Amount is met, the
additional security shall have attributed to it such value as the Facility Agent (acting on the instructions of the Majority Lenders) shall determine. 

  

	 	(c)	The Facility Agent shall be entitled to effect such security maintenance tests on a no more than semi-annual basis (commencing six (6) months from the date of this Agreement). For
the purposes of this Clause 16.12, the Market Value of the Vessels shall be determined in accordance with Clause 18.1(a) unless the Borrower procures an additional valuation determined in accordance with Clause 18.1(b), in which case the Market
Value of the Vessels for the purposes of this Clause 16.12 shall be the higher of the two valuations. 

  

	 	(d)	If any Vessel becomes a Total Loss, it shall, as of the earlier of (i) the date of receipt by the Facility Agent of the proceeds of insurance relating to such Total Loss or the
relevant prepayment in accordance with Clause 6.5 and (ii) the date falling one hundred and eighty (180) days after the occurrence of the relevant event of Total Loss, cease to be a Vessel for the purposes of this Clause 16.12, PROVIDED that, if any
insurance proceeds or Requisition Compensations are received by the Facility Agent in respect of a Total Loss of such Vessel they shall be applied in accordance with Clause 6.5(b); 

  

	 	(e)	If at any time any Vessel is not insured in accordance with the terms of the relevant Mortgage then, for so long as such Vessel is not insured in accordance with such requirements,
such Vessel shall, if the Facility Agent so determines, cease to be deemed a vessel for the purposes of this Clause 16.12. 

  

	 	(f)	Clauses 6.11 and 6.12 shall apply, mutatis mutandis, to any prepayment made pursuant to this Clause. Any prepayment made in accordance with this Clause 16.12 shall be applied
against the Repayment Instalments of the Loans in the inverse order of their maturity and pro rata between the Tranche A Loans and the Tranche B Loans. 

  

					
	 	 	50	 	21 July 2005

	16.13	Classification and repair 

  
 The Borrower will, and will procure that the Manager will from the Applicable Time: 
  

	 	(a)	ensure that the Vessels are surveyed from time to time as required by the classification society in which the Vessel is for the time being entered and maintain and preserve the
Vessel in good working order and repair, ordinary wear and tear excepted, and in any event in such condition as will entitle each to the classification of [100AI Containership, Shipright (SDA, FDA, CM)* IWS, X LMC, UMS, SCM, EP, CAC NAVI or, if such classification is not available with the highest equivalent classification available, with Lloyds Register][Seaspan
to confirm] of Shipping, (or to the equivalent classification in another internationally recognised classification society of like standing acceptable to the Facility Agent (acting on the instructions of the Majority Lenders)), free of all
overdue requirements and recommendations of that classification society; 

  

	 	(b)	procure that all repairs to or replacement of any damaged, worn or lost parts or equipment shall be effected in such manner (both as regards workmanship and quality of materials) as
not to diminish the value of the Vessels; 

  

	 	(c)	not remove any material part of any of the Vessels, or any item of equipment installed on any of the Vessels unless the part or item so removed is forthwith replaced by a suitable
part or item which is in the same condition as or better condition than the part or item removed, is free from any Security Interest (other than a Permitted Security Interest) or any right in favour of any person other than the Facility Agent and
becomes on installation on that Vessel the property of the Borrower and subject to the security constituted by the relevant Security Document(s) provided that the Borrower may install and remove equipment owned by a third party if the equipment can
be removed without any risk of damage to a Vessel; 

  

	 	(d)	ensure that each Vessel complies with all Applicable Laws from time to time applicable to vessels registered under the laws and flag of [Hong Kong] or such other flag, under which
the Vessels may be registered from time to time in accordance with this Agreement; and 

  

	 	(e)	not without the prior written consent of the Facility Agent (acting on the instructions of the Majority Lenders) (such consent not to be unreasonably withheld), cause or permit to
be made any substantial change in the structure, type or performance characteristics of any of the Vessels and provide notification of such substantial changes in structure, type or performance characteristics of any of the Vessels to the Facility
Agent and, furthermore, provide confirmation to the Facility Agent that such substantial change in structure, type or performance characteristics of any of the Vessels shall not result in a breach of any covenant under this Agreement.

  

	16.14	Lawful and Safe Operation 

  
 The Borrower will, and will procure that the Manager will, at all times after the Applicable Time: 
  

	 	(a)	operate each Vessel and cause each of the Vessels to be operated in a manner consistent in all material respects with any and all laws, regulations, treaties and conventions (and
all rules and regulations issued thereunder) from time to time applicable to the Vessel; 

  

	 	(b)	not cause or permit any of the Vessels to trade with, or within the territorial waters of any country in which her safety could reasonably be expected to be imperilled by exposure
to piracy, terrorism, arrest, requisition, confiscation, forfeiture, seizure, destruction or condemnation as prize; 

  

					
	 	 	51	 	21 July 2005

	 	(c)	not cause or permit any of the Vessels to be employed in any manner which will or may give rise to any reasonable degree of likelihood that such Vessel would be liable to
requisition, confiscation, forfeiture, seizure, destruction or condemnation as prize; 

  

	 	(d)	not cause or permit any of the Vessels to be employed in any trade or business which is forbidden by international law or is illicit or in carrying illicit or prohibited goods;

  

	 	(e)	in the event of hostilities in any part of the world (whether war be declared or not) not cause or permit any of the Vessels to be employed in carrying any contraband goods and that
she does not trade in any zone after it has been declared a war zone by any authority or by any of that Vessel’s war risks Insurers unless that Vessel’s Insurers shall have confirmed to the Borrower that such Vessel is held covered under
the Obligatory Insurances for the voyage(s) in question; and 

  

	 	(f)	not charter any of the Vessels or permit any of the Vessels to serve under any contract of affreightment with any foreign country or national of any foreign country which would be
contrary to Applicable Law or would render any Finance Document or the security conferred by the Security Documents unlawful. 

  

	16.15	Repair of the Vessels 

  
 The Borrower will not and will procure that the Manager will not, at any time after the Applicable Time, put any of the Vessels into the possession of any
person for the purpose of work being done upon her beyond the amount of US$5,000,000 (or equivalent), other than for classification or scheduled dry docking unless such person shall have given an undertaking to the Facility Agent not to exercise any
lien on that Vessel or Obligatory Insurances for the cost of that work or otherwise. 
  

	16.16	Arrests and Liabilities 

  
 The Borrower will, and will procure that the Manager will, at all times after the Applicable Time: 
  

	 	(a)	pay and discharge all obligations and liabilities whatsoever which have given or may give rise to liens (other than liens arising in the ordinary course of operation of any of the
Vessels in each case for amounts the payment of which is not yet due or, if due and payable, is being disputed in good faith by appropriate proceeding (and for the payment of which adequate reserves have been provided or are and continue to be
available)) on or claims enforceable against any of the Vessels and take all reasonable steps to prevent a threatened arrest of any of the Vessels; 

  

	 	(b)	notify the Facility Agent promptly in writing of the levy of either distress on any of the Vessels or her arrest, detention, seizure, condemnation as prize, compulsory acquisition
or requisition for title or use and (save in the case of compulsory acquisition or requisition for title or use) obtain her release within thirty (30) days; 

  

	 	(c)	pay and discharge when due all dues, taxes, assessments, governmental charges, fines and penalties lawfully imposed on or in respect of any of the Vessels or the Borrower except
those which are being disputed in good faith by appropriate proceedings (and for the payment of which adequate reserves have been provided or are and continue to be available) and provided that the continued existence of such dues, taxes,
assessments, governmental charges, fines or penalties does not give rise to any reasonable degree of likelihood that any of the Vessels would be liable to arrest, requisition, confiscation, forfeiture, seizure, destruction or condemnation as prize;
and 

  

					
	 	 	52	 	21 July 2005

	 	(d)	pay and discharge all other obligations and liabilities whatsoever in respect of any of the Vessels and the Obligatory Insurances except those which are being disputed in good faith
by appropriate proceedings (and for the payment of which adequate reserves have been provided or are and continue to be available) and provided that the continued existence of those obligations and liabilities in respect of any of the Vessels and
the Obligatory Insurances does not give rise to any reasonable degree of likelihood that the Vessel would be liable to arrest, requisition, confiscation, forfeiture, seizure, destruction or condemnation as prize and provided always that each Vessel
remains properly managed and insured at all times in accordance with the terms of this Agreement. 

  

	16.17	Related Contracts 

  
 The Borrower shall not take any action, enter into any document or agreement or omit to take any action or to enter into any document or agreement which
would, or could reasonably be expected to, cause any Related Contract to cease to remain in full force and effect and shall use all reasonable endeavours to procure that each other party to any Related Contract does not take any action, enter into
any document or agreement or omit to take any action or to enter into any document or agreement which would, or could reasonably be expected to, cause any Related Contract to cease to remain in full force and effect. 
  

	16.18	Environment 

  
 The Borrower shall, and shall procure that the Manager shall, at all times after the Applicable Time: 
  

	 	(a)	comply with all applicable Environmental Laws including, without limitation, requirements relating to the establishment of financial responsibility (and shall require that all
Environmental Affiliates of the Borrower comply with all applicable Environmental Laws and obtain and comply with all required Environmental Approvals, which Environmental Laws and Environmental Approvals relate to any of the Vessels or her
operation or her carriage of cargo); and 

  

	 	(b)	promptly upon the occurrence of any of the following events, provide to the Facility Agent a certificate of an officer of the Borrower or of the Borrower’s agents specifying in
detail the nature of the event concerned: 

  

	 	(i)	the receipt by the Borrower or any Environmental Affiliate (where the Borrower has knowledge of the receipt) of any Environmental Claim; or 

  

	 	(ii)	any Release of Hazardous Materials. 

  

	16.19	Information regarding the Vessels 

  
 The Borrower shall, and shall procure that the Manager shall, at all times after the Applicable Time: 
  

	 	(a)	promptly notify the Facility Agent of the occurrence of any accident, casualty or other event which has caused or resulted in or may cause or result in its Vessel being or becoming
a Total Loss; 

  

	 	(b)	promptly notify the Facility Agent of any requirement or recommendation made by any Insurer or classification society or by any competent authority which is not complied with in a
timely manner; 

  

					
	 	 	53	 	21 July 2005

	 	(c)	annually provide the Facility Agent with a schedule setting outgoing and all intended dry dockings of any of the Vessels, such schedule to form part of the Annual Compliance
Certificate; 

  

	 	(d)	promptly notify the Facility Agent of any Environmental Claim being made in connection with any of the Vessels or its operation; 

  

	 	(e)	promptly notify the Facility Agent of any claim for breach of the ISM Code being made in connection with any of the Vessels or its operation; 

  

	 	(f)	promptly notify the Facility Agent of any claim for breach of the ISPS Code being made in connection with any of the Vessels or its operation; 

  

	 	(g)	give to the Facility Agent from time to time on request such information, in sufficient copies (which may take the form of electronic copies) for all the Lenders, as the Facility
Agent may reasonably require regarding any of the Vessels, her employment, position and engagements; 

  

	 	(h)	provide the Facility Agent with copies of the classification certificate of the Vessels and of all periodic damage or survey reports on any of the Vessels which the Facility Agent
may reasonably request; 

  

	 	(i)	promptly furnish the Facility Agent with full information of any casualty or other accident or damage to any of the Vessels involving an amount in excess of US$1,500,000 (or
equivalent); 

  

	 	(j)	give to the Facility Agent and its duly authorised representatives reasonable access to any of the Vessels for the purpose of conducting on board inspections and/or surveys of the
Vessel and pay the reasonable expenses incurred by the Facility Agent in connection with the inspections and/or surveys provided that, unless a Default has occurred and is continuing, such inspections and/or surveys shall not take place at the
expense of the Borrower and the Facility Agent shall co-operate with the Borrower in respect of the timing for and the place where such surveys take place in order to minimise disruption to the activities of any of the Vessels; and

  

	 	(k)	if the Facility Agent reasonably believes an Event of Default may have occurred, furnish to the Facility Agent from time to time upon reasonable request certified copies of the
ship’s log in respect of any of the Vessels. 

  

	16.20	Provision of further information 

  
 The Borrower shall, and shall procure that the Manager shall, as soon as practicable following receipt of a request by the Facility Agent, provide the
Facility Agent, with sufficient copies for all the Lenders, with any additional or further financial or other information relating to any of the Vessels, the Obligatory Insurances or to any other matter relevant to, or to any provision of, a Finance
Document which the Facility Agent may reasonably request. 
  

	16.21	Management 

  
 The Borrower shall, and shall procure that the Manager shall, ensure that at all times after the Applicable Time: 
  

	 	(a)	the relevant Vessel is managed by the Manager; and 

  

					
	 	 	54	 	21 July 2005

	 	(b)	no Manager shall terminate or materially vary the terms of its management or appoint an alternative manager, provided that the Borrower shall be entitled so to do with the prior
written consent of the Facility Agent (acting on the instructions of the Majority Lenders). 

  
 However, in the event that a Manager’s appointment as manager of any one of the Vessels ceases or is terminated in circumstances where it was not
possible for the Borrower to obtain the prior written consent of the Facility Agent, the Borrower shall promptly and in any event within ten (10) days from the date of the termination of such Manager’s appointment, provide to the Facility Agent
details of a replacement manager, such manager to be satisfactory to the Facility Agent (acting on the instructions of the Majority Lenders). 
  

	16.22	Proceeds from sale or Total Loss of a Vessel 

  

	 	(a)	The Borrower shall procure that the proceeds from a sale or Total Loss of the relevant Vessel shall immediately upon receipt by the Borrower be paid into the Retention Account in
accordance with Clause 12.2 for application by the Facility Agent in accordance with Clause 12.3, unless an Event of Default has occurred and is continuing, in which case the proceeds from a sale or Total Loss of the relevant Vessel shall
immediately upon receipt by the Borrower be paid to the Facility Agent for application in accordance with Clause 13.7 (Payments). 

  

	 	(b)	For and so long as the Borrower holds any such proceeds as referred to in paragraph (a) it shall do so on trust for the Facility Agent. 

  

	16.23	Charters 

  

	 	(a)	No Borrower will let any of the Vessels on demise, consecutive voyage or voyage charter for any period without the consent of the Facility Agent (acting on the instructions of the
Majority Lenders) such consent not to be unreasonably withheld. 

  

	 	(b)	The Borrower shall be entitled to let its Initial Vessels, in accordance with the terms of the initial Time Charters PROVIDED always that: 

  

	 	(i)	the Borrower shall remain liable under any time charter to perform all the obligations assumed by it under the Time Charter; 

  

	 	(ii)	the Facility Agent shall not be under any obligations or liability under any time charter or liable to make any payment under that time charter; and 

  

	 	(iii)	the Facility Agent shall not be obliged to enforce against any charterer any term of any time charter, or to make any enquiries as to the nature or sufficiency of any payment
received by the Facility Agent. 

  

	 	(c)	The Borrower shall ensure that from the date of the Drawing under a Loan for the acquisition of an Additional Vessel, such Additional Vessel shall be the subject of a time charter
with a minimum term of one (1) year and otherwise in form and substance and with a charterer acceptable to the Facility Agent (acting on the instructions of the Majority Lenders, which instructions are to be given reasonably) and the Borrower shall
at all times ensure that: 

  

	 	(i)	the Borrower shall remain liable under any time charter to perform all the obligations assumed by it under that time charter; 

  

					
	 	 	55	 	21 July 2005

	 	(ii)	the Facility Agent shall not be under any obligations or liability under any time charter or liable to make any payment under that time charter; and 

  

	 	(iii)	the Facility Agent shall not be obliged to enforce against any charterer any term of any time charter, or to make any enquiries as to the nature or sufficiency of any payment
received by the Facility Agent. 

  

	16.24	Termination of Time Charter 

  

	 	(a)	At all times during the Post-Delivery Period, the Borrower shall advise the Facility Agent of any of the following events: 

  

	 	(i)	any breach (other than a technical breach which is cured promptly) by the relevant Charterer of the terms of a Time Charter of which the Borrower becomes aware;

  

	 	(ii)	the termination of a Time Charter by either the Borrower or the relevant Charterer; 

  

	 	(iii)	as soon as it becomes aware of such event, the occurrence of an event of cross default of the nature referred to in Clause 19.5 (Cross-default) in respect of a Charterer, PROVIDED
always that such event shall not arise in respect of the Charterer where the aggregate amount of the relevant Financial Indebtedness of the Charterer is less than US$50,000,000 or its equivalent; or 

  

	 	(iv)	as soon as it becomes aware of such event, the occurrence of an insolvency event of the nature referred to in Clause 19.6 (Insolvency), 19.7 (Insolvency proceedings), 19.8
(Creditor’s process) or 19.9 (Cessation of business) in respect of a Charterer, 

  
 and upon the occurrence of any such event the Facility Agent shall be (acting on the instructions of the Majority Lenders) entitled to require that the
Borrower exercises all of its rights under the relevant Time Charter including, where applicable, the termination of the Time Charter in respect of the relevant Vessel. 
  

	 	(b)	In the event of a termination of a Time Charter in accordance with Clause 16.24(a) or otherwise, in relation to which a charter termination fee is payable, such termination fee
shall be payable into the Retention Account in accordance with Clause 12.2. 

  

	 	(c)	In the event of a termination of a Time Charter referred to in paragraph (b) above the Borrower shall, within ninety (90) days of such termination, enter into a substitute time
charter with a charterer acceptable to the Lenders and with a term extending to at least the Final Maturity Date, such time charter to be in form and substance reasonably acceptable to the Facility Agent (acting on the instructions of the Majority
Lenders) and the relevant charter termination fee shall be released to the Borrower in accordance with Clause 12.3(b)(i), failing which either: 

  

	 	(i)	the charter termination fee shall be applied by the Facility Agent in prepayment of the relevant Loan to ensure that the Loan to Value Ratio is no greater than 60 per cent., and if
for any reason the amount of the charter termination fee shall be insufficient to make the prepayment described in this paragraph (i), the Borrower shall, without demand, provide the Facility Agent with an amount equal to the amount of the
shortfall; or 

  

	 	(ii)	the Borrower shall provide or cause to be provided to the Facility Agent such additional security as is satisfactory to the Facility Agent (acting on the instructions of the
Majority Lenders) so as to achieve the Loan to Value Ratio referred to in paragraph (i) above. 

  

					
	 	 	56	 	21 July 2005

	 	(d)	In the event of a termination or expiration of at least 50.1 per cent. of the Time Charters associated with either Lykes or CSCL or at least 50.1 per cent. of the Time Charters with
a particular Charterer in respect of the Additional Vessels in accordance with Clause 16.24(a) or otherwise, the Borrower shall, within ninety (90) days of such termination or expiration, enter into suitable substitute time charters each with a
charterer acceptable to the Lenders and with a term extending to at least the Final Maturity Date, each such time charter to be in form and substance reasonably acceptable to the Facility Agent (acting on the instructions of the Majority Lenders),
provided that all amounts due and payable by the Borrower under the Facility have been paid and no due and payable amounts remaining outstanding, failing which the Borrower shall either: 

  

	 	(i)	prepay the outstanding Loans in respect of the relevant Vessels to ensure that the aggregate of the Market Values of all of the Vessels actually delivered is not less than 150 per
cent. of the aggregate principal amount of the outstanding Loans in respect of the Vessels actually delivered; or 

  

	 	(ii)	the Borrower shall provide or cause to be provided to the Facility Agent such additional security as is satisfactory to the Facility Agent (acting on the instructions of the
Majority Lenders) so as to achieve the Loan to Value Ratio referred to in paragraph (i) above. 

  

	16.25	Scope of Obligatory Insurances 

  
 The Borrower will, in respect of each Vessel: 
  

	 	(a)	at all times after, in respect of the Delivered Vessels, the date of the first Drawing under the Delivered Vessels Loan or, in respect of the Subsequent Vessels and any Additional
Vessel, the date of a Drawing under the Loan for the financing of such Vessel, keep that Vessel insured in the Required Insurance Amount, in Dollars in the name of the Borrower or (if the Facility Agent so requires) in the joint names of the
Borrower and the Facility Agent without the Facility Agent being liable but having the right to pay premiums, through brokers approved by the Facility Agent (acting on the instructions of the Majority Lenders) against fire and usual marine risks
(including hull and machinery and Excess Risks) with approved underwriters or insurance companies approved by the Facility Agent (acting on the instructions of the Majority Lenders) and by policies in form and content approved by the Facility Agent
(acting on the instructions of the Majority Lenders); 

  

	 	(b)	at all times after, in respect of the Delivered Vessels, the date of the first Drawing under the Delivered Vessels Loan or, in respect of the Subsequent Vessels and any Additional
Vessel, the date of a Drawing under the Loan for the financing of such Vessel, keep that Vessel insured in the Required Insurance Amount in the same manner as above against war risks (including risks of mines and all risks, whether or not regarded
as war risks, London Blocking and Trapping Addendum and Lost Vessel Clause, excepted by the free of capture and seizure clauses in the standard form of Lloyds marine policy) either: 

  

	 	(i)	with underwriters or insurance companies approved by the Facility Agent (acting on the instructions of the Majority Lenders) and by policies in form and content approved by the
Facility Agent (acting on the instructions of the Majority Lenders); or 

  

	 	(ii)	by entering the relevant Vessel in an approved war risks association, 

  

					
	 	 	57	 	21 July 2005

 and for the avoidance of doubt, such war risks insurance will include protection and indemnity liability
up to at least the Required Insurance Amount, excluding any liability in respect of death, injury or damage to crew; 
  

	 	(c)	at all times after, in respect of the Delivered Vessels, the date of the first Drawing under the Delivered Vessels Loan or, in respect of the Subsequent Vessels and any Additional
Vessel, the date of a Drawing under the Loan for the financing of such Vessel, keep that Vessel entered in respect of her full value and tonnage in an approved protection and indemnity association against all risks as are normally covered by such
protection and indemnity association (including pollution risks and the proportion not recoverable in case of collision under the running down clause inserted in the ordinary Lloyds policies), such cover for pollution risks to be for:

  

	 	(i)	a minimum amount of US$1,000,000,000 or such other amount of cover against pollution risks as shall at any time be comprised in the basic entry of each Vessel with either a
protection and indemnity association which is an acceptable member of either the International Group of protection and indemnity associations (or any successor organisation designated by the Facility Agent for this purpose) or the International
Group (or such successor organisation) itself; or 

  

	 	(ii)	if the International Group or any such successor ceases to exist or ceases to provide or arrange any cover for pollution risks (or any supplemental cover for pollution risks over
and above that afforded by the basic entry of each Vessel with its protection and indemnity association), such aggregate amount of cover against pollution risks as shall be available on the open market and by basic entry with a protection and
indemnity association for ships of the same type, size, age and flag as each respective Vessel, 

  
 provided that, if any Vessel has ceased trading or is in lay up and in either case has unloaded all cargo, the level of pollution risks cover afforded by
ordinary protection and indemnity cover available through a member of the International Group or such successor organisation or, as the case may be, on the open market in such circumstances shall be sufficient for such purposes; and 
  

	 	(d)	at all times after the Delivery Date, whenever any Vessel is trading to Japanese territorial waters and when so required by the Facility Agent (acting on the instructions of the
Majority Lenders), maintain in full force and effect social responsibility insurance in respect of the Vessel with underwriters or insurance companies approved by the Facility Agent (acting on the instructions of the Majority Lenders) and by
policies in form and content approved by the Facility Agent (acting on the instructions of the Majority Lenders), provided always that a first class Borrower or operator of vessels such as the Vessels would maintain and effect such social
responsibility insurance. 

  

	16.26	Obligatory Insurances 

  
 Without prejudice to its obligations under Clause 16.25 (Scope of Obligatory Insurances), the Borrower will: 
  

	 	(a)	not without the prior consent of the Facility Agent (acting on the instructions of the Majority Lenders) alter any Obligatory Insurance nor make, do, consent or agree to any act or
omission which would or might render any Obligatory Insurance invalid, void, voidable or unenforceable or render any sum paid out under any Obligatory Insurance repayable in whole or in part; 

  

					
	 	 	58	 	21 July 2005

	 	(b)	not cause or permit any Vessel to be operated in any way inconsistent with the provisions or warranties of, or implied in, or outside the cover provided by, any Obligatory Insurance
or to be engaged in any voyage or to carry any cargo not permitted by any Obligatory Insurances without first covering the relevant Vessel in the relevant Required Insurance Amount and her freights for an amount approved by the Facility Agent
(acting on the instructions of the Majority Lenders) in Dollars or another approved currency with the Insurers; 

  

	 	(c)	duly and punctually pay when due all premiums, calls, contributions or other sums of money from time to time payable in respect of any Obligatory Insurance;

  

	 	(d)	renew all Obligatory Insurances at least fourteen (14) days before the relevant policies or contracts expire and procure that the approved brokers and/or war risks and protection
and indemnity clubs and associations shall promptly confirm in writing to the Facility Agent as and when each renewal is effected; 

  

	 	(e)	forthwith upon the effecting of any Obligatory Insurance, give written notice of the insurance to the Facility Agent stating the full particulars (including the dates and amounts)
of the insurance, and on request produce the receipts for each sum paid by it pursuant to paragraph (c) above; 

  

	 	(f)	not settle, release, compromise or abandon any claim in respect of any Total Loss unless the Facility Agent (acting on the instructions of the Majority Lenders) is satisfied that
such release, settlement, compromise or abandonment will not prejudice the interests of the Finance Parties under or in relation to any Finance Document; 

  

	 	(g)	arrange for the execution and delivery of such guarantees as may from time to time be required by any protection and indemnity or war risks club or association;

  

	 	(h)	procure that the interest of the Facility Agent is noted on all policies of insurance; 

  

	 	(i)	procure that a loss payee provision in the form scheduled to the Insurances Assignment and reflecting the provisions of Clause 16.27 (Application of Insurance Proceeds) is endorsed
on all policies of insurance; 

  

	 	(j)	obtain from the relevant insurance brokers and P&I Club letters of undertaking in the forms scheduled to the Insurances Assignments; and 

  

	 	(k)	in the event that the Borrower receives payment of any moneys under the Insurance Assignment, save as provided in the loss payable clauses scheduled to the Insurance Assignment,
forthwith pay over the same to the Facility Agent and, until paid over, such moneys shall be held in trust for the Facility Agent by the Borrower. 

  

	16.27	Application of Insurance Proceeds 

  

	 	(a)	All sums receivable in respect of the Obligatory Insurances after the occurrence of an Event of Default shall be paid to the Facility Agent and the Facility Agent shall apply them
in accordance with Clause 13.7 (Payments). 

  

	 	(b)	Subject to paragraph (a) above: 

  

	 	(i)	each sum receivable in respect of a major casualty (being any casualty in respect of which the claim or the aggregate of the claims exceeds US$20,000,000 (or its equivalent)), other
than in respect of protection and indemnity risk insurances, shall be paid to the Facility Agent; and 

  

					
	 	 	59	 	21 July 2005

	 	(ii)	the insurance moneys received by the Facility Agent in respect of any such major casualty shall be paid: 

  

	 	(A)	to the person to whom the relevant liability shall have been incurred; or 

  

	 	(B)	upon the Borrower furnishing evidence satisfactory to the Facility Agent that all loss and damage resulting from the casualty has been properly made good and repaired, to the
Borrower or, at the option of the Facility Agent, to the person by whom any repairs have been or are to be effected. 

  

	 	(iii)	The receipt by any such person referred to in paragraph (A) and (B) of paragraph (ii) above shall be a full and sufficient discharge of the same to the Facility Agent.

  

	 	(c)	Subject to paragraph (a) above, each sum receivable in respect of the Obligatory Insurances (insofar as the same are hull and machinery or war risks insurances) which does not
exceed US$20,000,000 or its equivalent shall be paid in full to the Borrower or to its order and shall be applied by it for the purpose of making good the loss and fully repairing all damage in respect of which the receivable shall have been
collected. 

  

	 	(d)	Subject to paragraph (a) above, each sum receivable in respect of protection and indemnity risk Obligatory Insurances shall be paid direct to the person to whom the liability, to
which that sum relates, was incurred, or to the Borrower in reimbursement to it of moneys expended in satisfaction of such liability. 

  

	 	(e)	Notwithstanding any other provision in this Clause 16.27, all sums receivable in respect of Obligatory Insurances relating to a Total Loss shall be applied in accordance with Clause
13.7 (Payments). 

  

	16.28	Power of Facility Agent to Insure 

  
 If the Borrower fails to effect and keep in force Obligatory Insurances in accordance with this Agreement, it shall be permissible, but not obligatory,
for the Facility Agent to effect and keep in force insurance or insurances in the amounts required under this Agreement and entries in a protection and indemnity association or club and, if it deems necessary or expedient, to insure the war risks
upon any Vessel, and the Borrower will reimburse the Facility Agent for the costs of so doing. 
  

	16.29	ISM Code 

  
 The Borrower shall, and shall procure that the Manager shall: 
  

	 	(a)	at all times after the Applicable Time be responsible for compliance by itself and by such Vessel with the ISM Code; 

  

	 	(b)	at all times after the Applicable Time ensure that: 

  

	 	(i)	the Vessel has a valid Safety Management Certificate (as defined in the ISM Code); 

  

	 	(ii)	the Vessel is subject to a safety management system (as defined in the ISM Code) which complies with the ISM Code; and 

  

	 	(iii)	there is a valid Document of Compliance (as defined in the ISM Code) for the Vessel, which is held on board the Vessel, 

  

					
	 	 	60	 	21 July 2005

 and shall deliver to the Facility Agent, on or before the Applicable Time, a copy of a valid Safety
Management Certificate and a valid Document of Compliance in respect of the relevant Vessel, in each case duly certified by an officer of the Borrower; 
  

	 	(c)	promptly notify the Facility Agent of any actual or, upon becoming aware of the same, threatened withdrawal of an applicable Safety Management Certificate or Document of Compliance;

  

	 	(d)	promptly notify the Facility Agent of the identity of the person ashore designated for the purposes of paragraph 4 of the ISM Code and of any change in the identity of that person;
and 

  

	 	(e)	promptly upon becoming aware of the same notify the Facility Agent of the occurrence of any accident or major non-conformity (as defined in the ISM Code) requiring action under the
ISM Code. 

  

	16.30	ISPS Code 

  
 The Borrower shall, and shall procure that the Manager shall, at all times after the Applicable Time: 
  

	 	(a)	comply and be responsible for compliance by itself and by such Vessel with the ISPS Code; 

  

	 	(b)	ensure that: 

  

	 	(i)	the Vessel has a valid International Ship Security Certificate; 

  

	 	(ii)	the Vessel’s security system and its associated security equipment comply with section 19.1 of Part A of the ISPS Code; 

  

	 	(iii)	the Vessel’s security system and its associated security equipment comply in all respects with the applicable requirements of Chapter XI-2 of SOLAS and Part A of the ISPS Code;
and 

  

	 	(iv)	an approved ship security plan is in place. 

  

	16.31	No amendment to Related Contracts 

  
 The Borrower shall not amend or agree to any amendment to the Related Contracts without the prior written consent of the Facility Agent. 
  

	16.32	Hedging Strategy 

  
 From the date of this Agreement until the Final Maturity Date, the Borrower shall maintain and implement the Hedging Policy. 
  

	16.33	Dry Docking 

  
 The Borrower shall procure that the Manager shall: 
  

	 	(a)	at all times retain sufficient liquid funds to ensure that, on the date of the scheduled dry docking of a Vessel, the Manager shall have sufficient available liquid funds to meet
all of its obligations under the Management Agreement including, but not limited to, the cost of such scheduled dry docking in relation to that Vessel; and 

  

					
	 	 	61	 	21 July 2005

	 	(b)	provide to the Facility Agent a certificate signed by the chief executive officer of the Manager in the form of Schedule 10 on a semi-annual basis (the first such certificate to be
provided six (6) months from the date of this Agreement). 

  

	17.	FINANCIAL COVENANTS 

  

	17.1	Definitions 

  
 In this Clause: 
  
 Cash and Cash Equivalents means, as at any date of determination: 
  

	 	(a)	cash in hand or on deposit in the Retention Account; 

  

	 	(b)	any investment in marketable obligations issued or guaranteed by the government of the United States of America, Canada or the United Kingdom or by an instrumentality or agency of
the government of the United States of America, Canada or the United Kingdom, maturing within one (1) year after the relevant date of calculation; 

  

	 	(c)	time deposits and certificates of deposit of any commercial bank having, or which is the principal banking subsidiary of a bank holding company having capital, surplus and undivided
profits aggregating in excess of [two hundred million Dollars (US$200,000,000)] which time deposits and certificates of deposit mature within one (1) year after the relevant date of calculation; 

  

	 	(d)	repurchase obligations with a term of not more than ninety (90) days for underlying securities of the type referred to in subclause (b) above entered into with any bank meeting the
qualifications specified in subclause (c) above; 

  

	 	(e)	open market commercial paper: 

  

	 	(i)	for which a recognised trading market exists; 

  

	 	(ii)	issued in the United States of America, Canada or the United Kingdom; 

  

	 	(iii)	which matures within one (1) year after the relevant date of calculation; and 

  

	 	(iv)	which has a credit rating of either A-1 by S&P or Fitch or P-1 by Moody’s, or, if no rating is available in respect of the commercial paper, the issuer of which has, in
respect of its long-term debt obligations, an equivalent rating; 

  

	 	(f)	any other instrument, security or investment approved by the Majority Lenders, 

  
 in each case, to which the Borrower is beneficially entitled at that time, which is unencumbered (other than by any of the
Security Documents) and which is capable of being applied against Total Borrowings. 
  
 EBITDA means the net income of the Borrower for a Measurement Period as adjusted by: 
  

	 	(a)	adding back taxation; 

  

	 	(b)	adding back Interest Expenses; 

  

	 	(c)	taking no account of any extraordinary item; 

  

					
	 	 	62	 	21 July 2005

	 	(d)	excluding any amount attributable to minority interests; 

  

	 	(e)	adding back depreciation and amortisation; and 

  

	 	(f)	taking no account of any revaluation of an asset or any loss or gain over book value arising on the disposal of an asset (otherwise than in the ordinary course of trading) by the
Borrower during that Measurement Period. 

  
 Interest and Principal Coverage Ratio means, as at any date of determination and with respect to any period, the ratio of EBITDA for such period to Interest and Principal Expense for such period. 
  
 Interest and Principal Expense means all Interest Expense incurred
and all payments of principal made by the Borrower during a Measurement Period. 
  
 Interest Expense means all cash interest and cash commitment fees incurred by the Group during a Measurement Period. 
  
 Marketable Securities means any bonds, stocks, notes or bills payable in a freely convertible and transferable currency and which are listed on a
stock exchange acceptable to the Facility Agent (acting on the instructions of the Majority Lenders). 
  
 Net Interest Coverage Ratio means, as at any date of determination and with respect to any period, the ratio of EBITDA for such period to Net
Interest Expense for such period. 
  
 Net Interest Expense
means Interest Expense less all interest and other financing charges received by the Seaspan Group during a Measurement Period. 
  
 Tangible Net Worth means at any time the amount paid up or credited as paid up on the issued share capital of the Borrower based on the latest
published audited balance sheet of the Borrower (the latest balance sheet) but adjusted by: 
  

	 	(a)	adding any amount standing to the credit of the profit and loss account of the Borrower for the period ending on the date of the latest balance sheet; 

  

	 	(b)	deducting any dividend or other distribution declared, recommended or made by the Borrower; 

  

	 	(c)	deducting any amount standing to the debit of the profit and loss account of the Borrower for the period ending on the date of the latest balance sheet; 

  

	 	(d)	deducting any amount attributable to goodwill (other than goodwill attributable to the Vessels) or any other intangible asset; 

  

	 	(e)	deducting any amount attributable to an upward revaluation of assets after the date of this Agreement; 

  

	 	(f)	adding the amount referred to in Schedule 11 for the date of the latest balance sheet which represents the difference between the purchase price of the Delivered Vessels paid by the
Borrower and the book value of the Delivered Vessels reduced for depreciation in equal increments over a thirty (30) year period; 

  

	 	(g)	reflecting any variation in the amount of the issued share capital of the Borrower and the capital and revenue reserves of the Borrower after the date of the latest balance sheet;

  

					
	 	 	63	 	21 July 2005

	 	(h)	reflecting any variation in the interest of the Borrower since the date of the latest balance sheet; 

  

	 	(i)	excluding any amount attributable to deferred taxation; and 

  

	 	(j)	excluding any amount attributable to minority interests. 

  
 Total Assets means, at any date, the aggregate of: 
  

	 	(a)	the then current book values of all vessels owned or leased with a purchase option by the Borrower, but adding back, in relation to the Delivered Vessels, the amount referred to in
paragraph (f) of the definition of Tangible Net Worth; 

  

	 	(b)	the then current aggregate amount of cash, Marketable Securities (but no other bonds, notes or bills and less any cash or Marketable Securities accounted for in the definition of
Total Borrowings below) and receivables due to the Borrower (less provision for bad and doubtful debts) as shown in the latest financial statements; and 

  

	 	(c)	the book values of all other (non-shipping) assets as shown in such latest financial statements. 

  
 Total Borrowings means, in respect of the Borrower, at any time the aggregate of the following: 
  

	 	(a)	the outstanding principal amount of any moneys borrowed; 

  

	 	(b)	the outstanding principal amount of any acceptance under any acceptance credit; 

  

	 	(c)	the outstanding principal amount of any bond, note, debenture, loan stock or other similar instrument; 

  

	 	(d)	the capitalised element of indebtedness under a finance or capital lease; 

  

	 	(e)	the outstanding principal amount of all moneys owing in connection with the sale or discounting of receivables (otherwise than on a non-recourse basis); 

  

	 	(f)	the outstanding principal amount of any indebtedness arising from any deferred payment agreements arranged primarily as a method of raising finance or financing the acquisition of
an asset; 

  

	 	(g)	any fixed or minimum premium payable on the repayment or redemption of any instrument referred to in paragraph (c) above; 

  

	 	(h)	the outstanding principal amount of any indebtedness arising in connection with any other transaction (including any forward sale or purchase agreement) which has the commercial
effect of a borrowing; and 

  

	 	(i)	the outstanding principal amount of any indebtedness of any person of a type referred to in the above paragraphs which is the subject of a guarantee, indemnity or similar assurance
against financial loss given by a member of the Seaspan Group. 

  

	17.2	Interpretation 

  

	 	(a)	Except as provided to the contrary in this Agreement, an accounting term used in this Clause is to be construed in accordance with U.S. GAAP. 

  

					
	 	 	64	 	21 July 2005

	 	(b)	Any amount in a currency other than Dollars is to be taken into account at its Dollar equivalent calculated on the basis of: 

  

	 	(i)	the Facility Agent’s spot rate of exchange for the purchase of the relevant currency in the London foreign exchange market with Dollars at or about 11.00 a.m. on the day the
relevant amount falls to be calculated; or 

  

	 	(ii)	if the amount is to be calculated on the last day of a financial period of the Borrower, the relevant rates of exchange used by the Borrower in, or in connection with, its financial
statements for that period. 

  

	 	(c)	No item must be credited or deducted more than once in any calculation under this Clause. 

  

	17.3	Tangible Net Worth 

  
 The Borrower must ensure that Tangible Net Worth always exceeds four hundred and fifty million Dollars (US$450,000,000). 
  

	17.4	Gearing 

  
 The Borrower must ensure that Total Borrowings are always less than 65 per cent. of Total Assets at that time. 
  

	17.5	Minimum Liquidity 

  
 If, at any time, more than 50 per cent. of the Vessels (assessed by value) are subject to time charters which have a remaining term of one year or less,
the Borrower must ensure that the Cash and Cash Equivalents held by the Borrower at such date of determination are not less than twenty five million Dollars (US$25,000,000). 
  

	17.6	Net Interest Coverage Ratio 

  
 The Borrower must ensure that the Net Interest Coverage Ratio is always greater than 2.50 to 1. 
  

	17.7	Interest and Principal Coverage Ratio 

  
 The Borrower must ensure that the Interest and Principal Coverage Ratio is always greater than or equal to 1.1 to 1. 
  

	17.8	Charter Default 

  
 The Borrower must ensure at all times following a breach by CSCL and/or Lykes (as applicable) of the terms of at least 51 per cent. of the Time Charters
entered into by CSCL and/or, as the case may be, Lykes, in circumstances where substitute charters complying with the requirements of Clause 16.24(Termination of Charter) have not been entered into by the Borrower within ninety (90) days of such
breach, that the aggregate Market Value of the Vessels shall not be less than 150 per cent. of the aggregate principal amount of the outstanding Loans. 
  

	17.9	Testing of Financial Covenants 

  

	 	(a)	Each of the financial covenants set out in Clauses 17.3 to 17.8 (inclusive) shall be tested by reference to each rolling twelve (12) month Measurement Period, provided always that
the Interest and Principal Coverage Ratio referred to in Clause 17.7 shall be tested on the basis of the financial statements of the Borrower for the last fiscal quarter of the Borrower in the event of the occurrence of the circumstances set out in
Clause 17.8. 

  

					
	 	 	65	 	21 July 2005

 (b) The Borrower shall provide a Compliance Certificate each quarter in respect of the financial
covenants. 
  

	18.	VALUATION 

  

	18.1	Valuation 

  
 For the purposes of this Clause 18: 
  

	 	(a)	the Initial Market Value of any Vessel and each subsequent valuation of a Vessel shall be the mean average of two valuations each certified in Dollars and carried out by two of the
Approved Valuers, reporting to the Facility Agent by way of written reports in form and substance satisfactory to the Facility Agent (acting reasonably) on the basis of a sale for prompt delivery of the Vessel for cash (free of Security Interests),
on a without charter basis and at arm’s-length on normal commercial terms as between willing seller and buyer. 

  

	 	(b)	In addition to the valuations to be carried out pursuant to Clause 18.1(a), following the calculation of its Initial Market Value, each Vessel shall, for the purposes of calculating
compliance with the Required Amount test pursuant to Clause 16.12 (Partial prepayments or additional security) and compliance with the financial covenant set out in Clause 17.8 (Charter Default) and if the Borrower so requires, be valued so that its
value is the aggregate of: 

  

	 	(i)	the present value of the bareboat equivalent rate (calculated as the rate of charterhire payable under the Time Charter for that Vessel less the amount of such charterhire which, in
accordance with the terms of that Time Charter, is allocated to operating expenses) for the remaining term of that Time Charter, excluding any options to renew or extend such term, such value to be certified in Dollars by the Facility Agent with a
discount rate of 7.00 per cent. to be applied for the present value calculation; and 

  

	 	(ii)	the present value of the relevant Vessel, calculated as the depreciated market value of that Vessel at the end of the term of the relevant Time Charter, excluding any options to
renew or extend such term, such value to be the mean average of two valuations each certified in Dollars and carried out by two of the Approved Valuers reporting to the Facility Agent on the basis of sale for cash (free of Security Interests), on a
without charter basis, at arm’s-length on normal commercial terms as between willing seller and buyer, and assuming an economic life of that Vessel from the Delivery Date of twenty five (25) years to a scrap value of US$125 per LDT. For the
present value calculation, the discount rate to be applied shall be 7.00 per cent. 

  

	 	(c)	In the case of each of (a) and (b) above, there shall be deducted from any value or valuation the amount which is owing or might become owing and which is secured on the asset
concerned by any prior or equal ranking Security Interest (other than in favour of the Facility Agent to secure the Secured Liabilities). 

  

	18.2	Delivery of Valuations 

  

	 	(a)	In respect of each Delivered Vessel, the Borrower will procure a valuation (being the Initial Market Value) on the basis described in Clause 18.1(a) prior to the date of the first
Drawing under the Delivered Vessels Loan. 

  

					
	 	 	66	 	21 July 2005

	 	(b)	In respect of each Subsequent Vessel, the Borrower will procure a valuation (being the Initial Market Value) on the basis described in Clause 18.1(a) prior to the date of a Drawing
under the Loan relating to such Vessel. 

  

	 	(c)	In respect of any Additional Vessel, the Borrower will procure a valuation (being the Initial Market Value) within a period of thirty (30) days prior to the earlier of (i) the date
of a Request in relation to a Drawing under a Tranche B Loan in respect of such Additional Vessel or (ii) the Delivery Date of such Additional Vessel. 

  

	 	(d)	In respect of the Vessels which have, at the relevant date, been delivered to the Borrower, the Borrower will procure a valuation on the basis described in Clause 18.1(a) and, if
the Borrower so requires, one valuation on the basis described in Clause 18.1(b) within each consecutive six (6) month period (the first such period commencing on the date of this Agreement) at the time required by the Facility Agent, prepared in
accordance with the relevant provisions of Clause 18.1 (Valuation). 

  

	 	(e)	The Borrower will procure in favour of the Facility Agent and the Approved Valuers, all such information, facilities and rights of inspection as they may reasonably (having regard
to the use and operation of the Vessel) require in order to effect such valuations. 

  

	 	(f)	Subject to Clause 18.2(h) below, all valuations shall be at the expense of the Borrower. 

  

	 	(g)	The Facility Agent shall be entitled to require that the Borrower provide a valuation in respect of a Vessel at any time during the Post-Delivery Period. In the event that such
valuation shows that the value of any of the Vessels does not reach the relevant Required Amount as required under Clause 16.12 the provisions of that Clause shall apply. 

  

	 	(h)	In the event that a valuation procured by the Facility Agent pursuant to Clause 18.2(g) does show that the relevant Required Amount is satisfied as required under Clause 16.12 and,
if applicable, that the financial covenant set out at Clause 17.8 is satisfied, such valuation shall be at the expense of the Facility Agent. 

  

	 	(i)	If an Event of Default has occurred and is continuing, the Borrower shall be liable to pay for such valuations of any Vessel from such of the Approved Valuers under Clause 18.2(a)
as the Facility Agent shall require. 

  

	 	(j)	Any valuation under this Clause 18 shall be binding and conclusive (save for manifest error). 

  

	19.	DEFAULT 

  

	19.1	Events of Default 

  
 Each of the events set out in this Clause 19 is an Event of Default. 
  

	19.2	Non-payment 

  
 The Borrower does not pay on the due date any amount payable by it under the Finance Documents in the manner required under the Finance Documents, unless
the non-payment: 
  

	 	(a)	is caused by technical or administrative error; and 

  

	 	(b)	is remedied within three (3) Business Days of the due date. 

  

					
	 	 	67	 	21 July 2005

	19.3	Breach of other obligations 

  

	 	(a)	The Borrower does not comply with any term of Clause 16 (General Covenants) or Clause 17 (Financial Covenants), unless the non-compliance: 

  

	 	(i)	is capable of remedy; and 

  

	 	(ii)	is remedied within thirty (30) days of the earlier of the Facility Agent giving notice to the Borrower and discovery (and for the purposes of this paragraph discovery means
actual awareness). 

  
 The Borrower acknowledges
that for the purposes of paragraph (i) above, non-compliance with the following shall not be capable of remedy: 
  

	 	(A)	Clause 16.10(a) and 16.10(b) (Security), but in respect of subparagraph (b) only insofar as it relates to the Mortgage, the Time Charter, Charter Guarantee and Earnings Assignment
and the Insurances Assignment; 

  

	 	(B)	Clause 16.11(a) (Registration of the Vessels); 

  

	 	(C)	the Obligatory Insurances being in full force and effect; and 

  

	 	(D)	Clause 17 (Financial Covenants), 

  
 provided always that, in the case of (A) and (B) above, if the non-compliance is caused by technical or administrative error only, is corrected within
three (3) Business Days of the earlier of the Facility Agent giving notice to the Borrower and discovery (discovery having the same meaning as in Clause 19.3(a)(ii)), and, in the case of (C) above, if the non-compliance is caused by technical
or administrative error only, is corrected within one (1) Business Day and in each case the Facility Agent (acting on the good faith and reasonable instructions of the Majority Lenders) is satisfied that the Finance Parties have neither suffered nor
will, in the future, suffer any material detriment (whether financial, to their security position or otherwise howsoever) as a result of the non-compliance. 
  

	 	(b)	Any Party (other than a Finance Party or the Account Bank) does not comply with any other term of the Finance Documents not already referred to in this Clause which the Facility
Agent (acting on the good faith and reasonable instructions of the Majority Lenders) considers to be material, unless the non-compliance: 

  

	 	(i)	is capable of remedy; and 

  

	 	(ii)	is remedied within fourteen (14) days of the earlier of the Facility Agent giving notice and discovery by the relevant Party (discovery having the same meaning as in Clause
19.3(a)(ii)) of the non-compliance. 

  

	19.4	Misrepresentation 

  
 A representation made or repeated by the Borrower (or by any other Party other than a Finance Party or the Account Bank) in any Finance Document or in any
document delivered by or on behalf of the Borrower under any Finance Document is incorrect in any respect which the Facility Agent (acting on the good faith and reasonable instructions of the Majority Lenders) considers to be material when made or
deemed to be repeated, unless the circumstances giving rise to the misrepresentation: 
  

	 	(a)	are capable of remedy; and 

  

					
	 	 	68	 	21 July 2005

	 	(b)	are remedied within thirty (30) days of the earlier of the Facility Agent giving notice and the relevant Party becoming aware of the misrepresentation. 

  

	19.5	Cross-default 

  
 Any of the following occurs in respect of the Borrower: 
  

	 	(a)	any of its Financial Indebtedness is not paid when due (after the expiry of any originally applicable grace period); 

  

	 	(b)	any of its Financial Indebtedness: 

  

	 	(i)	becomes prematurely due and payable; or 

  

	 	(ii)	is placed on demand; or 

  

	 	(iii)	is capable of being declared by a creditor to be prematurely due and payable or being placed on demand, 

  
 in each case, as a result of an event of default (howsoever described) and after the expiry of any applicable grace period;
or 
  

	 	(c)	any commitment for its Financial Indebtedness is cancelled or suspended as a result of an event of default (howsoever described), 

  
 unless the aggregate amount of Financial Indebtedness falling within
paragraphs (a) to (c) above is less than US$25,000,000 or its equivalent . 
  

	19.6	Insolvency 

  
 Any of the following occurs in respect of the Borrower: 
  

	 	(a)	it is, or is deemed for the purposes of any Applicable Law to be, unable to pay its debts as they fall due or insolvent; 

  

	 	(b)	it admits its inability to pay its debts as they fall due; 

  

	 	(c)	it suspends making payments on any of its debts or announces an intention to do so; 

  

	 	(d)	by reason of actual or anticipated financial difficulties, it begins negotiations with any creditor for the rescheduling of any of its indebtedness; or 

  

	 	(e)	a moratorium is declared in respect of any of its indebtedness. 

  
 If a moratorium occurs in respect of the Borrower, the ending of the moratorium will not remedy any Event of Default caused by the moratorium. 

 

	19.7	Insolvency proceedings 

  

	 	(a)	Except as provided in paragraph (b) below, any of the following occurs in respect of the Borrower: 

  

	 	(i)	any step is taken with a view to a moratorium, a composition, assignment or similar arrangement with any of its creditors; 

  

					
	 	 	69	 	21 July 2005

	 	(ii)	a meeting of its shareholders, directors or other officers is convened for the purpose of considering any resolution to petition for or to file documents with a court for its
winding-up, administration or dissolution or any such resolution is passed; 

  

	 	(iii)	any person presents a petition, or files documents with a court for its winding-up, administration or dissolution; 

  

	 	(iv)	an order for its winding-up, administration or dissolution is made; 

  

	 	(v)	any liquidator, trustee in bankruptcy, judicial custodian, compulsory manager, receiver, administrative receiver, administrator or similar officer is appointed in respect of it or
any of its assets; 

  

	 	(vi)	its directors, shareholders or other officers request the appointment of, or give notice of their intention to appoint a liquidator, trustee in bankruptcy, judicial custodian,
compulsory manager, receiver, administrative receiver, administrator or similar officer; or 

  

	 	(vii)	any other analogous step or procedure is taken in any jurisdiction. 

  

	 	(b)	Paragraph (a) above does not apply to a frivolous or vexatious petition for winding-up presented by a creditor which is being contested in good faith and with due diligence and is
discharged or struck out within fourteen (14) days. 

  

	19.8	Creditors’ process 

  
 Any attachment, sequestration, distress, execution or analogous event affects any asset(s) of the Borrower, having an aggregate value of twenty five
million Dollars (US$25,000,000) or its equivalent and is not discharged within thirty (30) days. 
  

	19.9	Cessation of business 

  
 The Borrower ceases, or threatens to cease, to carry on business except as a result of any disposal not prohibited under this Agreement. 
  

	19.10	Failure to pay final judgment 

  
 The Borrower fails to comply with or pay any sum due from it under any final judgment or any final order made or given by any court of competent
jurisdiction. 
  

	19.11	Effectiveness of Finance Documents 

  

	 	(a)	It is or becomes unlawful for the Borrower or any other Party (other than a Finance Party or the Account Bank) to perform any of its material obligations under the Finance
Documents. 

  

	 	(b)	Any material provision of a Finance Document is not effective or is alleged by the Borrower to be ineffective for any reason. 

  

	 	(c)	Any material provision of a Finance Document is not effective or is alleged by any Party (other than a Finance Party, the Borrower or the Account Bank) to be ineffective for any
reason. 

  

	 	(d)	The Borrower repudiates any material provision of a Finance Document or evidences an intention to repudiate any material provision of a Finance Document. 

 

					
	 	 	70	 	21 July 2005

	 	(e)	Any Party (other than a Finance Party or the Account Bank) repudiates any material provision of a Finance Document or evidences an intention to repudiate any material provision of a
Finance Document. 

  

	19.12	Invalidity of Security Documents 

  
 Any of the Security Documents ceases to be valid in any material respect or any of those Security Documents creating a Security Interest in favour of the
Facility Agent ceases to provide a perfected first priority security interest in favour of the Facility Agent. 
  

	19.13	Acceleration 

  
 If an Event of Default is outstanding, the Facility Agent, if the Majority Lenders so instruct it shall, by notice to the Borrower: 
  

	 	(a)	cancel the undrawn, uncancelled amount of the Maximum Facility Amount; and/or 

  

	 	(b)	declare that all or part of any amounts outstanding under the Finance Documents are: 

  

	 	(i)	immediately due and payable; and/or 

  

	 	(ii)	payable on demand by the Facility Agent. 

  
 Any notice given under this Subclause will take effect in accordance with its terms. 
  

	20.	SECURITY 

  

	20.1	Facility Agent as trustee 

  
 Unless expressly provided to the contrary herein or in any Finance Document and except as otherwise required by Applicable Law, the Facility Agent holds
any security created by a Security Document on trust for the Finance Parties. 
  

	20.2	Responsibility 

  
 The Facility Agent is not liable or responsible to any other Finance Party for: 
  

	 	(a)	any failure in perfecting or protecting the security created by any Security Document; or 

  

	 	(b)	any other action taken or not taken by it in connection with any Security Document, 

  
 unless directly caused by its gross negligence or wilful misconduct. 
  

	20.3	Title 

  
 The Facility Agent may accept, without enquiry, the title (if any) the Borrower may have to any asset over which security is intended to be created by any
Security Document. 
  

	20.4	Possession of documents 

  
 The Facility Agent is not obliged to hold in its own possession any Security Document, title deed or other document in connection with any asset over
which security is intended to be created by a Security Document. 
  

					
	 	 	71	 	21 July 2005

	20.5	Investments 

  
 Except as otherwise provided in any Security Document, all moneys received by the Facility Agent under a Security Document will, until utilised, be
invested in the name of, or under the control of, the Facility Agent in any investments selected by the Facility Agent (acting on the instructions of the Majority Lenders). Additionally, those moneys may be placed on deposit in the name of, or under
the control of, the Facility Agent at any bank or institution (including itself) and upon such terms as it may think fit. 
  

	20.6	Approval 

  
 Each Finance Party confirms its approval of each Security Document. 
  

	20.7	Release of security 

  

	 	(a)	If a disposal of any asset subject to security created by a Security Document is made to a person (which is and will remain) outside the Seaspan Group in the following
circumstances: 

  

	 	(i)	the Majority Lenders agree to the disposal; 

  

	 	(ii)	the disposal is allowed by the terms of the Finance Documents and will not result or could not reasonably be expected to result in any breach of any term of any Finance Document;

  

	 	(iii)	the disposal is being made at the request of the Facility Agent in circumstances where any security created by the Security Documents has become enforceable; or

  

	 	(iv)	the disposal is being effected by enforcement of a Security Document, 

  
 and, in any such case, the Facility Agent is satisfied that the relevant Loan will be prepaid in full in accordance with Clause 6.5(a)(i) (Mandatory
prepayment – Sale or Total Loss of a Vessel) at the time of the disposal, the asset being disposed of will be released from any security over it created by a Security Document. However, the proceeds of any disposal (or an amount corresponding
to them) must be applied in accordance with the requirements of the Finance Documents (if any). 
  

	 	(b)	Following the Final Maturity Date of any Loan, if that Loan has been irrevocably and unconditionally repaid in full to the satisfaction of the Finance Parties, and provided that
there is no breach of Clause 16.12 (Partial prepayments and additional security) at such time in respect of the remaining Vessel or Vessels, as the case may be, then the relevant Mortgage over the Vessel related to that Loan shall be released.

  

	 	(c)	If the Facility Agent is satisfied that a release is allowed under this Subclause, the Facility Agent must execute (at the request and expense of the Borrower) any document which is
reasonably required to achieve that release. Each other Finance Party irrevocably authorises the Facility Agent to execute any such document. 

  

	20.8	Co-security Agent 

  

	 	(a)	The Facility Agent may appoint a separate security agent or a co-security agent in any jurisdiction outside the United States of America: 

  

	 	(i)	if the Facility Agent considers that without the appointment the interests of the Lenders under the Finance Documents might be materially and adversely affected;

  

					
	 	 	72	 	21 July 2005

	 	(ii)	for the purpose of complying with any law, regulation or other condition in any jurisdiction; or 

  

	 	(iii)	for the purpose of obtaining or enforcing a judgment or enforcing any Finance Document in any jurisdiction. 

  

	 	(b)	Any appointment under this Subclause will only be effective if the security agent or co-security agent confirms to the Facility Agent and the Borrower in form and substance
satisfactory to the Facility Agent that it is bound by the terms of this Agreement as if it were the Facility Agent. 

  

	 	(c)	The Facility Agent may remove any security agent or co-security agent appointed by it and may appoint a new security agent or co-security agent in its place.

  

	 	(d)	The Borrower must pay to the Facility Agent any reasonable remuneration paid by the Facility Agent to any security agent or co-security agent appointed by it, together with any
related costs and expenses properly incurred by the security agent or co-security agent. 

  

	20.9	Parallel Debt 

  

	 	(a)	The Borrower hereby irrevocably and unconditionally undertakes to pay to the Facility Agent amounts equal to any amounts owing by the Borrower (whether owed as borrower of a
facility or as joint and several obligor) to the relevant Finance Parties under the Finance Documents as and when the same fall due for payment thereunder, so that the Facility Agent shall be the obligee of such covenant to pay and shall be entitled
to claim performance thereof in its own name and not as agent acting on behalf of the relevant Finance Parties. The Borrower and the Facility Agent acknowledge that for this purpose such obligations of the Borrower are several and are separate and
independent from, and without prejudice to, the identical obligations which the Borrower has to the Finance Parties under the relevant Finance Documents, provided that this shall not, at the same time, result in the Borrower incurring an aggregate
obligation to any such Finance Parties under the Finance Documents. To this end and without prejudice to the foregoing, it is agreed that (a) the amounts due and payable by the Borrower under this Clause 20.9 (the Parallel Debt) shall be
decreased to the extent that the Borrower paid any amounts to the Finance Parties or any of them in respect of the Secured Liabilities and vice versa and (b) the Parallel Debt shall not exceed the aggregate of the corresponding obligations which the
Borrower has to the Finance Parties under the Finance Documents. 

  

	 	(b)	Nothing in this Clause shall in any way negate, affect or increase the obligations of the Borrower to any Finance Parties under the Finance Documents in respect of the Secured
Liabilities. For the purpose of this Clause, the Facility Agent acts in its own name and on behalf of itself and not as agent or representative of any other party hereto and any security granted to the Facility Agent to secure the Parallel Debt is
granted to the Facility Agent in its capacity as creditor of the Parallel Debt and solely for the purpose referred to above. 

  

	20.10	Dutch Security 

  

	 	(a)	The Facility Agent shall obtain any Security Interest provided under or pursuant to a Security Document governed by Dutch law (the Dutch Security) in its own name.

  

	 	(b)	The Facility Agent shall have full and unrestricted entitlement to and authority in respect of the Dutch Security, provided that it shall be under an obligation to exercise such
rights (and perform such obligations) in accordance with the contractual undertakings set out in any Finance Document.][Subject to Account Bank being based in the Netherlands] 

  

					
	 	 	73	 	21 July 2005

	21.	THE ADMINISTRATIVE PARTIES 

  

	21.1	Appointment and duties of the Facility Agent 

  

	 	(a)	[Save as provided in Clause 20.10 (Dutch Security),] each Finance Party (other than the Facility Agent) irrevocably appoints the Facility Agent to act as its agent under the Finance
Documents. 

  

	 	(b)	Each Finance Party irrevocably authorises the Facility Agent to: 

  

	 	(i)	perform the duties and to exercise the rights, powers and discretions that are specifically given to it under the Finance Documents, together with any other incidental rights,
powers and discretions; and 

  

	 	(ii)	execute each Finance Document expressed to be executed by the Facility Agent. 

  

	 	(c)	The Facility Agent has only those duties which are expressly specified in the Finance Documents. Those duties are solely of a mechanical and administrative nature.

  

	21.2	Role of the Arrangers 

  
 Except as specifically provided in the Finance Documents, the Arrangers in their capacity as Arrangers have no obligations of any kind to any other Party
in connection with any Finance Document. 
  

	21.3	No fiduciary duties 

  
 Except as specifically provided in a Finance Document, nothing in the Finance Documents makes an Administrative Party a trustee or fiduciary for any other
Party or any other person. No Administrative Party needs to hold in trust any moneys paid to it for a Party or be liable to account for interest on those moneys. 
  

	21.4	Individual position of an Administrative Party 

  

	 	(a)	If it is also a Lender, each Administrative Party has the same rights and powers under the Finance Documents as any other Lender and may exercise those rights and powers as though
it were not an Administrative Party. 

  

	 	(b)	Each Administrative Party may: 

  

	 	(i)	carry on any business with the Borrower or its related entities (including acting as an agent or a trustee for any other financing); and 

  

	 	(ii)	retain any profits or remuneration it receives under the Finance Documents or in relation to any other business it carries on with the Borrower or its related entities.

  

	21.5	Reliance 

  
 The Facility Agent may: 
  

	 	(a)	rely on any notice or document believed by it to be genuine and correct and to have been signed by, or with the authority of, the proper person; 

  

	 	(b)	rely on any statement made by any person regarding any matters which may reasonably be assumed to be within his knowledge or within his power to verify; 

  

 74 

	 	(c)	engage, pay for and rely on professional advisors selected by it; and 

  

	 	(d)	act under the Finance Documents through its personnel and agents. 

  

	21.6	Majority Lenders’ instructions 

  

	 	(a)	The Facility Agent is fully protected if it acts on the instructions of the Majority Lenders in the exercise of any right, power or discretion or any matter not expressly provided
for in the Finance Documents. Any such instructions given by the Majority Lenders will be binding on all the Lenders. In the absence of instructions, then unless the Finance Documents expressly provide that the Facility Agent acts on the
instructions of the Majority Lenders in exercising the relevant right, power or discretion, the Facility Agent may act as it considers to be in the best interests of all the Lenders. 

  

	 	(b)	Each Lender acknowledges and confirms that it shall act in a reasonable manner when reaching any decision as to the exercise or non-exercise of any right, power or discretion by the
Facility Agent. 

  

	 	(c)	The Facility Agent may assume that unless it has received notice to the contrary, any right, power, authority or discretion vested in any Party or the Majority Lenders has not been
exercised. 

  

	 	(d)	The Facility Agent is not authorised to act on behalf of a Lender (without first obtaining that Lender’s consent) in any legal or arbitration proceedings in connection with any
Finance Document. 

  

	 	(e)	The Facility Agent may require the receipt of security satisfactory to it, whether by way of payment in advance or otherwise, against any liability or loss which it may incur in
complying with the instructions of the Majority Lenders. 

  

	21.7	Responsibility 

  

	 	(a)	No Administrative Party is responsible to any other Finance Party for the adequacy, accuracy or completeness of: 

  

	 	(i)	any Finance Document or any other document; or 

  

	 	(ii)	any statement or information (whether written or oral) made in or supplied in connection with any Finance Document. 

  

	 	(b)	Without affecting the responsibility of the Borrower for information supplied by it or on its behalf in connection with any Finance Document, each Lender confirms that it:

  

	 	(i)	has made, and will continue to make, its own independent appraisal of all risks arising under or in connection with the Finance Documents (including the financial condition and
affairs of the Borrower and its related entities and the nature and extent of any recourse against any Party or its assets); and 

  

	 	(ii)	has not relied exclusively on any information provided to it by any Administrative Party in connection with any Finance Document. 

  

					
	 	 	75	 	21 July 2005

	21.8	Exclusion of liability 

  

	 	(a)	The Facility Agent is not liable or responsible to any other Finance Party for any action taken or not taken by it in connection with any Finance Document, unless directly caused by
its gross negligence or wilful misconduct. 

  

	 	(b)	No Party (other than the Facility Agent) may take any proceedings against any officer, employee or agent of the Facility Agent in respect of any claim it might have against the
Facility Agent or in respect of any act or omission of any kind by that officer, employee or agent in connection with any Finance Document. Any officer, employee or agent of the Facility Agent may rely on this Subclause and enforce its terms under
the Contracts (Rights of Third Parties) Act 1999. 

  

	21.9	Default 

  

	 	(a)	The Facility Agent is not obliged to monitor or enquire whether a Default has occurred. The Facility Agent is not deemed to have knowledge of the occurrence of a Default.

  

	 	(b)	If the Facility Agent: 

  

	 	(i)	receives notice from a Party referring to this Agreement, describing a Default and stating that the event is a Default; or 

  

	 	(ii)	is aware of the non-payment of any principal or interest or any fee payable to a Lender under this Agreement, 

  
 it must promptly notify the Lenders. 
  

	21.10	Information 

  

	 	(a)	The Facility Agent must promptly forward to the person concerned the original or a copy of any document which is delivered to the Facility Agent by a Party for that person.

  

	 	(b)	Except where a Finance Document specifically provides otherwise, the Facility Agent is not obliged to review or check the adequacy, accuracy or completeness of any document it
forwards to another Party. 

  

	 	(c)	Except as provided above, the Facility Agent has no duty: 

  

	 	(i)	either initially or on a continuing basis to provide any Lender with any credit or other information concerning the risks arising under or in connection with the Finance Documents
(including any information relating to the financial condition or affairs of the Borrower or its related entities or the nature or extent of recourse against any Party or its assets) whether coming into its possession before, on or after the date of
this Agreement; or 

  

	 	(ii)	unless specifically requested to do so by a Lender in accordance with a Finance Document, to request any certificate or other document from the Borrower. 

 

	 	(d)	In acting as the Facility Agent, the agency division of the Facility Agent is treated as a separate entity from its other divisions and departments. Any information acquired by the
Facility Agent which, in its opinion, is acquired by it otherwise than in its capacity as the Facility Agent may be treated as confidential by the Facility Agent and will not be treated as information possessed by the Facility Agent in its capacity
as such. 

  

					
	 	 	76	 	21 July 2005

	 	(e)	The Borrower irrevocably authorises the Facility Agent to disclose to the other Finance Parties any information which, is received by it in its capacity as the Facility Agent.

  

	21.11	Indemnities 

  

	 	(a)	Without limiting the liability of the Borrower under the Finance Documents, each Lender must indemnify the Facility Agent for that Lender’s Pro Rata Share of any loss or
liability incurred by the Facility Agent in acting as the Facility Agent, except to the extent that the loss or liability is caused by the Facility Agent’s gross negligence or wilful misconduct. 

  

	 	(b)	The Facility Agent may deduct from any amount received by it for a Lender any amount due to the Facility Agent from that Lender under a Finance Document but unpaid.

  

	21.12	Compliance 

  
 Each Administrative Party may refrain from doing anything (including disclosing any information) which might, based on the reasonable opinion of its legal
counsel, constitute a breach of any law or regulation or be otherwise actionable at the suit of any person, and may do anything which, in its opinion, is necessary or desirable to comply with any law or regulation. 
  

	21.13	Resignation of the Facility Agent 

  

	 	(a)	The Facility Agent may resign by giving written notice to the Lenders and the Borrower, in which case the Majority Lenders shall appoint a successor facility agent of which the
Borrower approves, such approval not to be unreasonably withheld or delayed. 

  

	 	(b)	If no successor Facility Agent has been appointed under paragraph (a) above within thirty (30) days after notice of resignation was given, the Facility Agent may appoint a successor
Facility Agent. 

  

	 	(c)	The resignation of the Facility Agent and the appointment of any successor facility agent will both become effective only when the successor facility agent (i) notifies all the
Parties that it accepts its appointment and (ii) confirms that it is satisfied that the rights under the Security Documents have been assigned or transferred to it. On giving the notification and confirmation, the successor facility agent will
succeed to the position of the Facility Agent and the term Facility Agent will mean the successor facility agent. 

  

	 	(d)	The retiring Facility Agent must, at its own cost, make available to the successor Facility Agent such documents and records and provide such assistance as the successor Facility
Agent may reasonably request for the purposes of performing its functions as the Facility Agent under the Finance Documents. 

  

	 	(e)	Upon its resignation becoming effective, this Clause will continue to benefit the retiring Facility Agent in respect of any action taken or not taken by it in connection with the
Finance Documents while it was the Facility Agent, and, subject to paragraph (d) above, it will have no further obligations in its capacity as Facility Agent under any Finance Document. 

  

	 	(f)	The Majority Lenders may, by notice to the Facility Agent, require it to resign under paragraph (a) above. 

  

					
	 	 	77	 	21 July 2005

	21.14	Relationship with Lenders 

  

	 	(a)	The Facility Agent may treat each Lender as a Lender entitled to payments under this Agreement and as acting through its Facility Office(s) until it has received not less than five
(5) Business Days’ prior notice from that Lender to the contrary. 

  

	 	(b)	The Facility Agent may at any time, and must if requested to do so by the Majority Lenders, convene a meeting of the Lenders. 

  

	 	(c)	The Facility Agent must keep a register of all the Parties and supply any other Party with a copy of the register on request. The register will include each Lender’s Facility
Office(s) and contact details for the purposes of this Agreement. 

  

	21.15	Notice period 

  
 Where this Agreement specifies a minimum period of notice to be given to the Facility Agent, the Facility Agent may, at its discretion, accept a shorter
notice period. 
  

	22.	EVIDENCE AND CALCULATIONS 

  

	22.1	Accounts 

  
 Accounts maintained by the Facility Agent in connection with this Agreement are conclusive (save for manifest error) evidence of the matters to which they
relate for the purpose of any litigation or arbitration proceedings. 
  

	22.2	Certificates and determinations 

  
 Any certification or determination by the Facility Agent of a rate or amount under the Finance Documents will be, in the absence of manifest error,
conclusive evidence of the matters to which it relates. 
  

	22.3	Calculations 

  
 Any interest or fee accruing under this Agreement accrues from day to day and is calculated on the basis of the actual number of days elapsed and a year
of 360 days or otherwise, depending on what the Facility Agent determines is market practice. 
  

	23.	FEES 

  

	23.1	Commitment fee 

  

	 	(a)	The Borrower must pay to the Facility Agent for and on behalf of the Lenders a commitment fee calculated at the rate of 37.5 per cent. of the Margin from time to time per annum on
the undrawn, uncancelled amount of the Maximum Facility Amount. The commitment fee shall accrue from the day following the Closing Date. 

  

	 	(b)	Accrued commitment fee is payable quarterly in arrears and on the last day of each Term. Accrued commitment fee is also payable to the Facility Agent for a Lender on the date its
Commitment is cancelled in full. 

  

					
	 	 	78	 	21 July 2005

	23.2	Participation fee 

  
 The Borrower must pay to the Facility Agent for the benefit pro rata of the Lenders a participation fee in the manner agreed in the Fee Letter
between the Arrangers, the Facility Agent and the Borrower. 
  

	23.3	Underwriting and Arrangement fee 

  
 The Borrower must pay to the Arrangers and the Lenders underwriting and structuring fees in the manner agreed in the Fee Letter between the Arrangers, the
Facility Agent and the Borrower. 
  

	23.4	Structuring and Bookrunning fee 

  
 The Borrower must pay to the Arrangers structuring and bookrunning fees in the manner agreed in the Fee Letter between the Arrangers, the Facility Agent
and the Borrower. 
  

	23.5	Facility Agent’s fee 

  
 The Borrower must pay to the Facility Agent an agency and security trustee fee in the manner agreed in the Fee Letter between the Arrangers, the Facility
Agent and the Borrower. 
  

	23.6	Refund of fees 

  
 The fees referred to in this Clause 23 and the Fee Letter shall not be refunded under any circumstances whatsoever once they have been paid. 

 

	24.	INDEMNITIES AND BREAK COSTS 

  

	24.1	Currency indemnity 

  

	 	(a)	The Borrower shall, as an independent obligation and within three (3) Business Days of demand, indemnify each Finance Party against any cost, loss or liability which that Finance
Party incurs as a consequence of: 

  

	 	(i)	the Finance Party receiving an amount in respect of the Borrower’s liability under the Finance Documents; or 

  

	 	(ii)	that liability being converted into a claim, proof, judgment or order, 

  
 in a currency other than the currency in which the amount is expressed to be payable under the relevant Finance Document. 
  

	 	(b)	The Borrower waives any right it may have in any jurisdiction to pay any amount under the Finance Documents in a currency other than that in which it is expressed to be payable.

  

	24.2	Other indemnities 

  

	 	(a)	The Borrower shall, as an independent obligation and within three (3) Business Days of demand, indemnify each Finance Party against any cost, loss or liability which that Finance
Party incurs as a consequence of: 

  

	 	(i)	the occurrence of any Event of Default; 

  

	 	(ii)	any failure by the Borrower to pay any amount due under a Finance Document on its due date; 

  

					
	 	 	79	 	21 July 2005

	 	(iii)	(other than by reason of negligence or default by that Finance Party) a Loan (or part of a Loan) not being made after a Request has been delivered for that Loan; or

  

	 	(iv)	a Loan (or part of a Loan) not being prepaid in accordance with a notice of prepayment. 

  
 The liability of the Borrower in each case includes any cost, loss or expense on account of funds borrowed, contracted for
or utilised to fund any amount payable under any Finance Document, any amount repaid or prepaid or any Loan. 
  

	 	(b)	The Borrower must indemnify against any cost, loss or liability incurred by any Finance Party as a result of: 

  

	 	(i)	investigating any event which that Finance Party reasonably believes to be a Default; or 

  

	 	(ii)	acting or relying on any notice of the Borrower which that Finance Party reasonably believes to be genuine, correct and appropriately authorised. 

  

	 	(c)	The Borrower must indemnify and agree to hold harmless the Finance Parties and in each case, each of its and their Affiliates and each of their respective officers, directors,
employees, agents, advisors and representatives (each, an Indemnified Party) from and against any and all claims, damages, losses, liabilities, costs, legal expenses and expenses (altogether Losses), joint or several, that may be
incurred by or asserted or awarded against any Indemnified Party, in each case arising out of or in connection with or relating to any claim, investigation, litigation or proceeding (or the preparation of any defence with respect thereto) commenced
or threatened in relation to the Finance Documents or the Related Contracts (or the transactions contemplated hereby or thereby) or any use made or proposed to be made with the proceeds of the Facility. This indemnity shall apply whether or not such
claims, investigation, litigation or proceeding is brought by the Borrower, the shareholders of the Borrower or the creditors of the Borrower, an Indemnified Party or any other person, or an Indemnified Party is otherwise a party thereto, except to
the extent such Losses are found in a final, non-appealable judgment by a court of competent jurisdiction to have resulted from such Indemnified Party’s gross negligence or wilful misconduct. 

  

	 	(d)	No Indemnified Party shall have any liability (whether direct or indirect, in contract, tort or otherwise) to the Borrower or any shareholders or creditors of the Borrower for or in
connection with the transactions referred to in paragraph (c) above, except for direct (as opposed to indirect or consequential) damages or losses to the extent such liability is found in a final non-appealable judgment by a court of competent
jurisdiction to have resulted from such Indemnified Party’s gross negligence or wilful misconduct. 

  

	 	(e)	The Borrower must indemnify and hold each Finance Party harmless on a full indemnity basis, from and against each and every Loss: 

  

	 	(i)	 arising directly or indirectly out of or in any way connected with the ownership, possession, performance, transportation, management, sale, import to or export
from any jurisdiction, control, use or operation, registration, navigation, certification, classification, management, manning, provisioning, the provision of bunkers and lubricating oils, testing, design, condition, delivery, acceptance, leasing,
subleasing, chartering, insurance, maintenance, repair, service, modification, refurbishment, dry docking, survey, conversion, overhaul, replacement, removal, repossession, return, redelivery, storage, sale, disposal, the complete or partial
removal, decommissioning, making safe, destruction, abandonment or loss by the Borrower 

  

					
	 	 	80	 	21 July 2005

 
or any other person of any of the Vessels or caused by any of the Vessels becoming a wreck or an obstruction to navigation, whether or not such liability may
be attributable to any defect in any of the Vessels or to the design, construction or use thereof or from any maintenance, service, repair, dry docking, overhaul, inspection or for any other reason whatsoever (whether similar to any of the foregoing
or not), and regardless of when the same shall arise and whether or not any of the Vessels (or any part thereof) is in possession or control of the Borrower or the Manager or any other person and whether or not the same is in United Kingdom waters
or abroad; 
  

	 	(ii)	arising directly or indirectly out of or in any way connected with any Release of Hazardous Material, any Environmental Claim, or any breach of an Environmental Law or the terms and
conditions of an Environmental Approval; 

  

	 	(iii)	as a consequence of any claim that any design, article or material in any of the Vessels or any part thereof or relating thereto or the operation or use thereof constitutes an
infringement of patent, copyright, design or other proprietary right; or 

  

	 	(iv)	in preventing or attempting to prevent the arrest, seizure, taking in execution, requisition, impounding, forfeiture or detention of any of the Vessels or in securing or attempting
to secure the release of any of the Vessels. 

  

	24.3	Break Costs 

  

	 	(a)	The Borrower must pay to each Lender or, as the case may be, each Swap Counterparty, its Break Costs in accordance with this Agreement. 

  

	 	(b)	In respect of a Lender, Break Costs are the amount (if any) determined by the relevant Lender by which: 

  

	 	(i)	the interest which that Lender would have received for the period from the date of receipt of payment of a Loan or an overdue amount to the last day of the current Term for that
Loan or overdue amount if the principal or overdue amount received had been paid on the last day of that Term; 

  
 exceeds 
  

	 	(ii)	the amount which that Lender would be able to obtain by placing an amount equal to the amount received by it on deposit with a leading bank in the appropriate interbank market for a
period starting on the Business Day following receipt and ending on the last day of the applicable Term. 

  

	 	(c)	In respect of a Swap Counterparty, Break Costs are the amount (if any) determined by that Swap Counterparty which would indemnify that Swap Counterparty against any loss or
liability that it incurs as a consequence of terminating all or any part of the swap or other hedging arrangements under any Swap Agreement. 

  

	 	(d)	Each Lender, or as the case may be, each Swap Counterparty, must supply to the Borrower details of the amount of any Break Costs claimed by it under this Clause.

  

					
	 	 	81	 	21 July 2005

	25.	EXPENSES 

  

	25.1	Initial costs 

  
 The Borrower must pay to each Finance Party the amount of all reasonable costs and expenses (including legal fees) incurred by it in connection with (but
not limited to) the negotiation, preparation, printing and execution of the Finance Documents. 
  

	25.2	Subsequent costs 

  
 The Borrower must pay to each Finance Party the amount of all reasonable costs and expenses (including legal fees) incurred by it in connection with:

  

	 	(a)	the negotiation, preparation, printing and execution of any Finance Document (other than a Transfer Certificate) executed after the date of this Agreement; and

  

	 	(b)	any amendment, waiver or consent requested by or on behalf of the Borrower or specifically allowed by this Agreement. 

  
 The Borrower shall not be required to bear the amount of any costs and
expenses (including legal fees) incurred by a Lender or a New Lender (as that term is defined in Clause 28.2 (Assignments and transfers by Lenders)) in connection with any voluntary transfer made by a Lender under this Agreement or any of the
Security Agreements. In the event that a Lender is required to undertake any such transfers as a result of the provisions of Clause 11.4 (Mitigation) any costs of that Lender or a New Lender arising out of such transfer shall be payable by the
Borrower. 
  

	25.3	Enforcement costs 

  
 The Borrower must pay to each Finance Party the amount of all costs and expenses (including legal fees) incurred by it in connection with the enforcement
or attempted enforcement of, or the preservation or attempted preservation of any rights under, any Finance Document. 
  

	26.	WAIVER OF CONSEQUENTIAL DAMAGES 

  
 In no event shall any Finance Party be liable on any theory of liability for any special, indirect, consequential or punitive damages and the Borrower
hereby waives, releases and agrees (for itself and on behalf of its Subsidiaries) not to sue upon any such claim for any such damages, unless caused by the fraud, wilful default or recklessness of the relevant Finance Party in performance of any of
its obligations under this Agreement or any of the Finance Documents. 
  

	27.	AMENDMENTS AND WAIVERS 

  

	27.1	Procedure 

  

	 	(a)	Except as provided in this Clause 27, no term of the Finance Documents may be amended or waived without the agreement of the Borrower and the Majority Lenders. The Facility Agent
may effect, on behalf of any Finance Party, an amendment or waiver allowed under this Clause. 

  

	 	(b)	The Facility Agent must promptly notify the other Parties of any amendment or waiver effected by it under paragraph (a) above. Any such amendment or waiver is binding on all the
Parties. 

  

					
	 	 	82	 	21 July 2005

	27.2	Exceptions 

  

	 	(a)	An amendment or waiver which relates to: 

  

	 	(i)	the definition of Majority Lenders in Clause 1.1 (Definitions); 

  

	 	(ii)	an extension of the date of payment of any amount to a Lender under the Finance Documents; 

  

	 	(iii)	a reduction in the amount of any payment of principal, interest, fee or other amount payable to a Lender under the Finance Documents; 

  

	 	(iv)	an increase in, or an extension of, a Commitment or the Total Commitments; 

  

	 	(v)	a release of the Borrower; 

  

	 	(vi)	a term of a Finance Document which expressly requires the consent of each Lender; 

  

	 	(vii)	the right of a Lender to assign or transfer its rights or obligations under the Finance Documents; or 

  

	 	(viii)	a reduction in the Margin or the Interest Rate; 

  

	 	(ix)	this Clause, 

  
 may only be made with the consent of all the Lenders and the Borrower such consent not to be unreasonably withheld or delayed. 
  

	 	(b)	An amendment or waiver which relates to the rights or obligations of an Administrative Party may only be made with the consent of that Administrative Party, the Majority Lenders and
the Borrower. 

  

	27.3	Change of currency 

  
 If a change in any currency of a country occurs (including where there is more than one currency or currency unit recognised at the same time as the
lawful currency of a country), the Finance Documents will be amended to the extent the Facility Agent (acting reasonably and on the instructions of the Majority Lenders and after consultation with the Borrower) determines is necessary to reflect the
change. 
  

	27.4	Waivers and remedies cumulative 

  
 The rights of each Finance Party under the Finance Documents: 
  

	 	(a)	may be exercised as often as necessary; 

  

	 	(b)	are cumulative and not exclusive of its rights under the general law; and 

  

	 	(c)	may be waived only in writing and specifically. 

  
 Delay in exercising or non-exercise of any right is not a waiver of that right. 
  

					
	 	 	83	 	21 July 2005

	28.	CHANGES TO THE PARTIES 

  

	28.1	Assignments and transfers by Borrower 

  
 The Borrower may not assign or transfer any of its rights and obligations under the Finance Documents without the prior consent of all the Lenders.

  

	28.2	Assignments and transfers by Lenders 

  

	 	(a)	A Lender (the Existing Lender) may, subject to the following provisions of this Subclause, at any time assign or transfer (including by way of novation) any of its rights and
obligations under this Agreement to another bank, financial institution or to a trust, fund or other entity which is regularly engaged or established for the purpose of making, purchasing or otherwise investing in loans, securities or other
financial assets (the New Lender), provided always that: 

  

	 	(i)	each assignment or transfer shall be uniform, and not a varying percentage of all rights and obligations under this Agreement; 

  

	 	(ii)	each assignment or transfer shall not result in increased liability to the Borrower; 

  

	 	(iii)	the Facility Agent shall provide to the Borrower details of the proposed new lenders at least seven (7) Business Days prior to the proposed transfer date and the Borrower shall
approve or object to the identity of any one or more of the proposed new lenders on such list (such approval not to be unreasonably withheld or delayed). The relevant Lender shall be entitled to effect a transfer or assignment to any proposed new
lender on such list to which the Borrower has not objected on reasonable grounds within such seven (7) Business Day period; 

  

	 	(iv)	the Existing Lender shall first offer to transfer or assign its rights to a lender participating in an Existing Credit Facility. The lender will be deemed to have rejected the offer
if such lender has not accepted within fifteen (15) days of receipt of the offer; 

  

	 	(v)	during primary syndication the number of Lenders shall not exceed 20 unless the prior written consent of the Borrower is obtained (such consent not to be unreasonably withheld);

  

	 	(vi)	following primary syndication, the Arrangers shall use their best commercial efforts to maintain the number of Lenders at twenty (20) and at no time shall the number of Lenders
exceed twenty five (25) unless the prior written consent of the Borrower is obtained (such consent not to be unreasonably withheld). 

  

	 	(b)	Unless the Borrower otherwise agrees (acting reasonably), a transfer of part of a Commitment or the rights and obligations under this Agreement by the Existing Lender must be in a
minimum amount of twenty five million Dollars (US$25,000,000) unless the Commitment of the Existing Lender is less than such amount in which case the whole of the Commitment of the Existing Lender may be transferred. 

  

	 	(c)	A transfer of part of a Commitment or the rights and obligations under this Agreement by the Existing Lender will be pro rata between its Tranche A Commitments and its
Tranche B Commitments. 

  

	 	(d)	A transfer of obligations will be effective only if either: 

  

	 	(i)	the obligations are novated in accordance with the following provisions of this Clause 28; or 

  

					
	 	 	84	 	21 July 2005

	 	(ii)	the New Lender confirms to the Facility Agent and the Borrower in form and substance reasonably satisfactory to the Facility Agent and the Borrower that it is bound by the terms of
this Agreement. 

  

	 	(e)	On the transfer becoming effective in this manner, the relevant Lender will be released from its obligations under this Agreement to the extent that they are transferred to the New
Lender. 

  

	 	(f)	Any reference in this Agreement to a Lender includes a New Lender but excludes a Lender if no amount is or may be owed to or by it under this Agreement. 

  

	28.3	Procedure for transfer by way of novations 

  

	 	(a)	In this Subclause: 

  
 Transfer Date means, for a Transfer Certificate, the later of: 
  

	 	(i)	the proposed Transfer Date specified in that Transfer Certificate; and 

  

	 	(ii)	the date on which the Facility Agent executes that Transfer Certificate. 

  

	 	(b)	A novation is effected if: 

  

	 	(i)	the Existing Lender and the New Lender deliver to the Facility Agent a duly completed Transfer Certificate; and 

  

	 	(ii)	the Facility Agent executes it. 

  

	 	(c)	On the Transfer Date: 

  

	 	(i)	the New Lender will assume the rights and obligations of the Existing Lender expressed to be the subject of the novation in the Transfer Certificate in substitution for the Lender;
and 

  

	 	(ii)	the Existing Lender will be released from those obligations and cease to have those rights. 

  

	 	(d)	Each Party (other than the Existing Lender and the New Lender) irrevocably authorises the Facility Agent to execute any duly completed Transfer Certificate on its behalf.

  

	28.4	Limitation of responsibility of Existing Lender 

  

	 	(a)	Unless expressly agreed to the contrary, an Existing Lender is not responsible to a New Lender for: 

  

	 	(i)	the legality, validity, effectiveness, completeness, accuracy, adequacy or enforceability of any Finance Document or any other document; 

  

	 	(ii)	the financial condition of the Borrower; 

  

	 	(iii)	the performance and observance by the Borrower of its obligations under the Finance Documents or any other documents; or 

  

					
	 	 	85	 	21 July 2005

	 	(iv)	the accuracy of any statement or information (whether written or oral) made in or supplied in connection with any Finance Document, 

  
 and any representations or warranties implied by law are excluded.

  

	 	(b)	Each New Lender confirms to the Existing Lender that it: 

  

	 	(i)	has made, and will continue to make, its own independent appraisal of all risks arising under or in connection with the Finance Documents (including the financial condition and
affairs of the Borrower and its related entities and the nature and extent of any recourse against any Party or its assets) in connection with its participation in this Agreement; and 

  

	 	(ii)	has not relied exclusively on any information supplied to it by the Existing Lender in connection with any Finance Document. 

  

	 	(c)	Nothing in any Finance Document requires an Existing Lender to: 

  

	 	(i)	accept a re-transfer from a New Lender of any of the rights and obligations assigned or transferred under this Clause; or 

  

	 	(ii)	support any losses incurred by the New Lender by reason of the non-performance by the Borrower of its obligations under any Finance Document or otherwise. 

 

	28.5	Costs resulting from change of Lender or Facility Office 

  
 If: 
  

	 	(a)	a Lender assigns or transfers any of its rights and obligations under the Finance Documents or changes its Facility Office; and 

  

	 	(b)	as a result of circumstances existing at the date of assignment, transfer or change occurs, the Borrower would be obliged to pay a Tax Payment or an Increased Cost,

  
 then, unless the assignment, transfer or change
is made by a Lender to mitigate any circumstances giving rise to a Tax Payment, Increased Cost or a right to be prepaid and/or cancelled by reason of illegality, the Borrower need only pay that Tax Payment or Increased Cost to the same extent that
it would have been obliged to if no assignment, transfer or change had occurred. 
  

	28.6	Changes to the Reference Banks 

  
 If a Reference Bank (or, if a Reference Bank is not a Lender, the Lender of which it is an Affiliate) ceases to be a Lender, the Facility Agent must (in
consultation with the Borrower) appoint another Lender or an Affiliate of a Lender to replace that Reference Bank. 
  

	29.	DISCLOSURE OF INFORMATION 

  
 Each Finance Party may disclose such information as that Finance Party shall consider appropriate in respect of information supplied to it, by or on
behalf of the Borrower, the Seaspan Group, the Charterers or the Finance Documents to: 
  

	 	(a)	in the case of any other Finance Party, any of its Affiliates; or 

  

	 	(b)	 any other person who has not been objected to by the Borrower pursuant to Clause 27.2(a)(C) (Assignments and transfers by Lenders), to (or through) whom an Existing

  

					
	 	 	86	 	21 July 2005

 
Lender assigns or transfers (or may potentially assign or transfer) all or any of its rights and obligations under this Agreement or with (or through) whom a
Lender enters into (or may potentially enter into) any sub-participation in relation to, or any other transaction under which payments are to be made by reference to, this Agreement or the Borrower; or 
  

	 	(c)	any person to whom, and to the extent that, information is required to be disclosed by any Applicable Law; or 

  

	 	(d)	any other Finance Party; or 

  

	 	(e)	to its and the Borrower’ professional advisors, 

  
 PROVIDED ALWAYS that, in relation to paragraph (b) above, the person to whom the information is to be given has entered into a Confidentiality
Undertaking. Except as provided in this Clause, a Lender may not disclose any information about the Borrower, the Seaspan Group, the Charterers or the Finance Documents to any person. 
  

	30.	SET-OFF 

  
 A Finance Party may set off any matured obligation owed to it by the Borrower under the Finance Documents against any obligation (whether or not matured)
owed by that Finance Party to the Borrower, regardless of the place of payment, booking branch or currency of either obligation. If the obligations are in different currencies, that Finance Party may convert either obligation at a market rate of
exchange in its usual course of business for the purpose of the set-off. 
  

	31.	PRO RATA SHARING 

  

	31.1	Redistribution 

  
 If any amount owing by the Borrower under this Agreement to a Lender (the recovering Lender) is discharged by payment, set-off or any other manner
other than through the Facility Agent under this Agreement (a recovery), then: 
  

	 	(a)	the recovering Lender must, within three (3) Business Days, supply details of the recovery to the Facility Agent; 

  

	 	(b)	the Facility Agent must calculate whether the recovery is in excess of the amount which the recovering Lender would have received if the recovery had been received by the Facility
Agent under this Agreement; and 

  

	 	(c)	the recovering Lender must pay to the Facility Agent an amount equal to such excess (the redistribution). 

  

	31.2	Effect of redistribution 

  

	 	(a)	The Facility Agent must treat a redistribution as if it were a payment by the Borrower under this Agreement and distribute it among the Lenders, other than the recovering Lender,
accordingly. 

  

	 	(b)	When the Facility Agent makes a distribution under paragraph (a) above, the recovering Lender will be subrogated to the rights of the Finance Parties which have shared in that
redistribution. 

  

					
	 	 	87	 	21 July 2005

	 	(c)	If and to the extent that the recovering Lender is not able to rely on any rights of subrogation under paragraph (b) above, the Borrower will owe the recovering Lender a debt which
is equal to the redistribution, immediately payable and of the type originally discharged. 

  

	 	(d)	If: 

  

	 	(i)	a recovering Lender must subsequently return a recovery, or an amount measured by reference to a recovery, to the Borrower; and 

  

	 	(ii)	the recovering Lender has paid a redistribution in relation to that recovery, 

  

each Finance Party must reimburse the recovering Lender all or the appropriate portion of the redistribution paid to that Finance Party, together with
interest for the period while it held the re-distribution. In this event, the subrogation in paragraph (b) above will operate in reverse to the extent of the reimbursement. 
  

	31.3	Exceptions 

  
 Notwithstanding any other term of this Clause, a recovering Lender need not pay a redistribution to the extent that: 
  

	 	(a)	it would not, after the payment, have a valid claim against the Borrower in the amount of the redistribution; or 

  

	 	(b)	it would be sharing with another Finance Party any amount which the recovering Lender has received or recovered as a result of legal or arbitration proceedings, where:

  

	 	(i)	the recovering Lender notified the Facility Agent of those proceedings; and 

  

	 	(ii)	the other Finance Party had an opportunity to participate in those proceedings but did not do so or did not take separate legal or arbitration proceedings as soon as reasonably
practicable after receiving notice of them. 

  

	32.	SEVERABILITY 

  
 If a term of a Finance Document is or becomes illegal, invalid or unenforceable in any jurisdiction, that shall not affect: 
  

	 	(a)	the legality, validity or enforceability in that jurisdiction of any other term of the Finance Documents; or 

  

	 	(b)	the legality, validity or enforceability in other jurisdictions of that or any other term of the Finance Documents. 

  

	33.	COUNTERPARTS 

  
 Each Finance Document may be executed in any number of counterparts and by facsimile provided that original signed copies are provided within a reasonable
period of time thereafter. This has the same effect as if the signatures on the counterparts were on a single copy of the Finance Document. 
  

					
	 	 	88	 	21 July 2005

	34.	NOTICES 

  

	34.1	In writing 

  

	(a)	Any communication in connection with a Finance Document must be in writing and, unless otherwise stated, may be given in person, by post, fax, e-mail or by any other electronic
communication approved by the Facility Agent. 

  

	(b)	For the purpose of the Finance Documents, an electronic communication will be treated as being in writing. 

  

	(c)	Unless it is agreed to the contrary, any consent or agreement required under a Finance Document must be given in writing. 

  

	34.2	Contact details 

  

	 	(a)	Except as provided below, the contact details of each Party for all communications in connection with the Finance Documents are those notified by that Party for this purpose to the
Facility Agent on or before the date it becomes a Party. 

  

	 	(b)	The contact details of all of the Borrower for this purpose are: 

  

			
	 Address:
	  	[•]
	 Fax number:
	  	[•]
	 Attention:
	  	[•]
	
	 with a copy to each of:

		
	 Address:
	  	2600-200 Granville Street, Vancouver, B.C., Canada V6C 1S4
	 Fax number:
	  	604-331-0925
	 Attention:
	  	Gerry Wang, President
		
	 Address:
	  	[10 Pemberton Avenue, North Vancouver, B.C. Canada V7P 2R1]
	 Fax number:
	  	[604-984-1615]
	 Attention:
	  	Kevin Kennedy, Chief Financial Officer

  

	 	(c)	The contact details of the Facility Agent for this purpose are: 

  

			
		
	 Address:
	  	Three Stamford Plaza
	 	  	301 Tresser Boulevard
	 	  	Stamford, Connecticut
	 	  	CT 06901-3239, USA
	 Fax number:
	  	001 203 705 5888
	 Attention:
	  	Loan Administration

  

	 	(d)	A Party may change its contact details by giving five (5) Business Days’ notice to the Facility Agent or (in the case of the Facility Agent) to the other Parties.

  

	 	(e)	Where a Party nominates a particular department or officer to receive a communication, a communication will not be effective if it fails to specify that department or officer.

  

	34.3	Effectiveness 

  

	 	(a)	Except as provided below, any communication in connection with a Finance Document will be deemed to be given as follows: 

  

	 	(i)	if delivered in person, at the time of delivery; 

  

					
	 	 	89	 	21 July 2005

	 	(ii)	if posted, five (5) days after being deposited in the post, postage prepaid, in a correctly addressed envelope; 

  

	 	(iii)	if by fax, when received in legible form; and 

  

	 	(iv)	if by e-mail or any other electronic communication, when received in legible form. 

  

	 	(b)	A communication given under paragraph (a) above but received on a non-working day or after business hours in the place of receipt will only be deemed to be given on the next working
day in that place. 

  

	 	(c)	A communication to the Facility Agent will only be effective on actual receipt by it. 

  

	34.4	Borrower 

  
 All communications under the Finance Documents to or from the Borrower must be sent through the Facility Agent. 
  

	34.5	Entire Agreement 

  
 This Agreement and the other Finance Documents entered into pursuant to this Agreement contain the whole agreement between the parties relating to the
transactions contemplated by this Agreement and supersede all previous agreements between the parties relating to such transactions. 
  

	35.	LANGUAGE 

  

	 	(a)	Any notice given in connection with a Finance Document must be in English. 

  

	 	(b)	Any other document provided in connection with a Finance Document must be: 

  

	 	(i)	in English; or 

  

	 	(ii)	(unless the Facility Agent otherwise agrees) accompanied by a certified English translation. In this case, the English translation prevails unless the document is a statutory or
other official document. 

  

	36.	GOVERNING LAW 

  
 This Agreement is governed by English law. 
  

	37.	ENFORCEMENT 

  

	37.1	Jurisdiction 

  

	 	(a)	The English courts have jurisdiction to settle any dispute in connection with any Finance Document. 

  

	 	(b)	The English courts are the most appropriate and convenient courts to settle any such dispute. 

  

	 	(c)	This Clause is for the benefit of the Lenders only. To the extent allowed by law, the Lenders may take: 

  

	 	(i)	proceedings in any other court; and 

  

	 	(ii)	concurrent proceedings in any number of jurisdictions. 

  

					
	 	 	90	 	21 July 2005

	37.2	Service of process 

  

	 	(a)	The Borrower irrevocably appoints Clifford Chance Secretaries Limited of 10 Upper Bank Street, London, E14 5JJ as its agent under the Finance Documents for service of process in any
proceedings before the English courts. 

  

	 	(b)	If any person appointed as process agent is unable for any reason to act as agent for service of process, the Borrower must immediately appoint another agent on terms acceptable to
the Facility Agent. Failing this, the Facility Agent may appoint another agent for this purpose. 

  

	 	(c)	The Borrower agrees that failure by a process agent to notify it of any process will not invalidate the relevant proceedings. 

  

	 	(d)	This Clause does not affect any other method of service allowed by law. 

  

	37.3	Waiver of immunity 

  
 The Borrower irrevocably and unconditionally: 
  

	 	(a)	agrees not to claim any immunity from proceedings brought by a Finance Party against it in relation to a Finance Document and to ensure that no such claim is made on its behalf;

  

	 	(b)	consents generally to the giving of any relief or the issue of any process in connection with those proceedings; and 

  

	 	(c)	waives all rights of immunity in respect of it or its assets. 

  
 THIS AGREEMENT has been entered into on the date stated at the beginning of this Agreement. 
  

					
	 	 	91	 	21 July 2005

 SCHEDULE 1 
  
 ORIGINAL PARTIES 
  
 PART 1 
  
 ORIGINAL OWNERS AND THE INITIAL VESSELS 
  

									
	 DELIVERED VESSELS
	  	 	  	 
					
	 Vessel

	  	Vessel Name

	  	Size
(teu)

	  	 Original Owner

	  	Charterer

	 1
	  	CSCL Hamburg	  	4,250	  	CSCL Hamburg Shipping Company Limited	  	CSCL
					
	 2
	  	CSCL Chiwan	  	4,250	  	CSCL Chiwan Shipping Company Limited	  	CSCL
					
	 3
	  	CSCL Ningbo	  	4,250	  	CSCL Ningbo Shipping Company Limited	  	CSCL
					
	 4
	  	CSCL Dalian	  	4,250	  	CSCL Dalian Shipping Company Limited	  	CSCL
					
	 5
	  	CSCL Felixstowe	  	4,250	  	CSCL Felixstowe Shipping Company Limited	  	CSCL
					
	 6
	  	CSCL Oceania	  	8,500	  	Clorina Marine Company Limited	  	CSCL
					
	 7
	  	CSCL Africa	  	8,500	  	Elia Shipping Company Limited	  	CSCL
					
	 8
	  	CSCL Vancouver	  	4,250	  	Vancouver Shipping Company Limited	  	CSCL
					
	 9
	  	CSCL Sydney	  	4,250	  	Tofino Shipping Company Limited	  	CSCL
					
	 10
	  	CSCL New York	  	4,250	  	Nootka Shipping Company Limited	  	CSCL

  

									
	 SUBSEQUENT VESSELS
	  	 	  	 
					
	 Vessel

	  	Vessel Name

	  	Size
(teu)

	  	 Original Owner

	  	Charterer

	 11
	  	CSCL Melbourne	  	4,250	  	Nanaimo Shipping Company Limited	  	CSCL
					
	 12
	  	CSCL Brisbane	  	4,250	  	Burrard Shipping Company Limited	  	CSCL
					
	 13
	  	Lykes Charger	  	4,250	  	Seaspan King Shipping Company Limited	  	Lykes
					
	 14
	  	TMM Guerrero	  	4,250	  	Seaspan Queen Shipping Company Limited	  	Lykes
					
	 15
	  	Containership Banyan	  	4,250	  	Seaspan Knight Shipping Company Limited	  	Lykes
					
	 16
	  	Lykes Merchant	  	4,250	  	Seaspan Bishop Shipping Company Limited	  	Lykes
					
	 17
	  	TMM Morelos	  	4,250	  	Seaspan Castle Shipping Company Limited	  	Lykes
					
	 18
	  	Containership Margosa	  	4,250	  	Seaspan Pawn Shipping Company Limited	  	Lykes
					
	 19
	  	Lykes Victor	  	4,250	  	Seaspan Ace Shipping Company Limited	  	Lykes
					
	 20
	  	TMM Nuevo Leon	  	4,250	  	Seaspan Eagle Shipping Company Limited	  	Lykes
					
	 21
	  	Containership Cassia	  	4,250	  	Seaspan Birdie Shipping Company Limited	  	Lykes
					
	 22
	  	CSCL Zeebrugge	  	9,600	  	Hemlock Shipping Company Limited	  	CSCL
					
	 23
	  	CSCL Long Beach	  	9,600	  	Spruce Shipping Company Limited	  	CSCL

  

					
	 	 	92	 	21 July 2005

 PART 2 
  
 ORIGINAL LENDERS 
  

							
	 Name of Original Lender

	  	 Tranche A
 Commitments (US$)

	 	 	 Tranche B
 Commitments (US$)

	 
	 Citibank, N.A.
	  	[163,125,000	]	 	[54,437,500	]
	 Credit Suisse
	  	[163,125,000	]	 	[54,437,500	]
	 DnB Nor Bank ASA
	  	[163,125,000	]	 	[54,437,500	]
	 Fortis Capital Corp.
	  	[163,125,000	]	 	[54,437,500	]
	 Landesbank Hessen-Thüringen
	  	97,500,000	 	 	32,500,000	 

  

					
	 	 	93	 	21 July 2005

 SCHEDULE 2 
  
 INITIAL CONDITION PRECEDENT DOCUMENTS 
  
 PART 1 
  
 TRANCHE A INITIAL CONDITIONS PRECEDENT DOCUMENTS 
  

	1.	Borrower 

  

	(a)	A certified copy* of the constitutional documents of the Borrower or, if the Facility Agent already has a copy, a certificate of the Borrower certifying that the copy in the
Facility Agent’s possession is still correct, complete and in full force and effect as at a date no earlier than the date of the Request together with an up to date Certificate of Goodstanding dated no more than ten (10) Business Days prior to
the first Utilisation Date. 

  

	(b)	A certified copy* of a resolution of the board of directors of the Borrower (unless such resolution in relation to the issues below is still in full force and effect):

  

	 	(i)	approving the terms of, and the transactions contemplated by, each Finance Document and each Related Contract to which the Borrower is a party and resolving that it executes each
such Finance Document and each Related Contract, then to be executed; 

  

	 	(ii)	authorising a specified person or persons to execute each Finance Document and each Related Contract on its behalf to which it is a party, then to be executed; and

  

	 	(iii)	authorising a specified person or persons, on its behalf, to sign and/or despatch all other documents and notices to be signed and/or despatched by it under or in connection with
each Finance Document and each Related Contract to which it is a party, then to be executed. 

  

	(c)	A specimen of the signature of each person authorised by the resolution referred to in paragraph 1(b) above. 

  

	(d)	A certified copy* of all other resolutions, consents, licences, exemptions and filings, corporate, official or otherwise which the Lender may reasonably require in connection with
this Agreement or any other Finance Document. 

  

	2.	Finance Documents and Related Contracts 

  

	(a)	A duly executed original of this Agreement (to be provided at the time of the initial Tranche A Request only). 

  

	(b)	A duly executed original of each Time Charter and Earnings Assignment relating to each Vessel the subject of a Drawing under a Tranche A Loan. 

  

	(c)	A duly executed original of the Retention Account Charge (to be provided at the time of the initial Tranche A Request only). 

  

	(d)	A duly executed original of the Fee Letter (to be provided at the time of the initial Tranche A Request only). 

  

	(e)	A duly executed original of the Charter Guarantee Assignment relating to each Vessel the subject of a Drawing under a Tranche A Loan (if applicable). 

  

					
	 	 	94	 	21 July 2005

	(f)	A duly executed original of the Mortgage relating to each Vessel the subject of a Drawing under a Tranche A Loan; 

  

	(g)	A duly executed original of the Deed of Covenants relating to each Vessel the subject of a Drawing under a Tranche A Loan; 

  

	(h)	A duly executed original of the Insurances Assignment relating to each Vessel the subject of a Drawing under a Tranche A Loan; 

  

	(i)	A duly executed original of the Management Agreement Assignment (to be provided at the time of the initial Tranche A Request only); 

  

	(j)	A duly executed original of each of the Manager’s Undertakings relating to each Vessel the subject of a Drawing under a Tranche A Loan; 

  

	(k)	A certified copy of the Management Agreement, duly executed; 

  

	(l)	A duly executed original of the relevant Swap Agreement(s); 

  

	(m)	A duly executed original of the Swap Mortgage relating to each Vessel the subject of a Drawing under a Tranche A Loan; and 

  

	(n)	A duly executed original of the Swap Deed of Covenants relating to each Vessel the subject of a Drawing under a Tranche A Loan; 

  

	(o)	A certified copy* of each Time Charter (including the documentation by which the benefit and burden of such Time Charter has been transferred to the Borrower from the Original
Owner), duly executed. 

  

	(p)	A certified copy* of each Charter Guarantee (if applicable), duly executed. 

  

	(q)	A certified copy* of the documentation pursuant to which each Vessel the subject of a Drawing under a Tranche A Loan has been sold to the Borrower (in the case of Delivered Vessels)
or the benefit and burden in relation to that Vessel have been transferred to the Borrower (in the case of Subsequent Vessels). 

  

	(r)	Duly executed originals of all notices of assignment required to be served under each Security Document referred to above and faxed copies of the acknowledgements thereof (where it
is not possible to provide originals of the same, with such originals to follow as soon as practicable after the first Utilisation Date), duly executed by each relevant counterparty. 

  

	3.	Other documents 

  

	(a)	A copy of any other authorisation or other document, opinion or assurance which the Facility Agent considers to be necessary or desirable in connection with the entry into and
performance of, and the transactions contemplated by, any Finance Document or any Related Contract or for the validity and enforceability of any Finance Document or any Related Contract. 

  

	(b)	A letter from Clifford Chance Secretaries Limited agreeing to its appointment as process agent for the Borrower under the Finance Documents. 

  

	(c)	A letter from China Shipping (UK) Agency Co., Ltd. or [CP Ships Services Inc.], as appropriate, agreeing to its appointment as process agent for CSCL or Lykes (as appropriate) in
respect of the acknowledgement of the relevant Time Charter and Earnings Assignment and, if applicable, the Charter Guarantee Assignment. 

  

					
	 	 	95	 	21 July 2005

	(d)	A letter from the Borrower to Facility Agent (duly acknowledged by the Facility Agent) detailing Hedging Policy to be implemented. 

  

	4.	The Vessel to be delivered 

  

	(a)	A certified copy* of: 

  

	 	(i)	a classification certificate in respect of the Vessel showing the Vessel to be in class without recommendation, condition or qualification or, in the event that this is not
available, a faxed copy with a certified copy to follow as soon as practicable after, in respect of the Delivered Vessels, the date of this Agreement or, in respect of a Subsequent Vessel, the relevant Delivery Date; 

  

	 	(ii)	a valid Interim Safety Management Certificate for the Vessel; 

  

	 	(iii)	a valid Document of Compliance; and 

  

	 	(iv)	a valid International Ship Security Certificate for the Vessel. 

  

	(b)	Evidence acceptable to the Facility Agent that immediately following the relevant Drawing the Vessel will be delivered to the Borrower (whether under the relevant Shipbuilding
Contract or otherwise) and title (as described in paragraph 1(a)(ii) of Schedule 3) to the Vessel will pass to the Borrower. 

  

	5.	Insurance 

  

	(a)	A certified copy of all current insurance policies in respect of the Vessel. 

  

	(b)	A duly executed and, where necessary, notarised notice of assignment (and acknowledgement of the same) of the Obligatory Insurances in respect of the Vessel duly executed by the
Borrower substantially in the form provided for in the Insurances Assignment. 

  

	(c)	Fax confirmation from each broker and club concerned with the Obligatory Insurances of the Vessel that: 

  

	 	(i)	the relevant cover is in effect; 

  

	 	(ii)	they will accept notice of assignment of the Obligatory Insurances in favour of the Facility Agent and execute an acknowledgement of the notice in the form required by the Facility
Agent; 

  

	 	(iii)	they will restrict their lien for unpaid premiums under any fleet policy to unpaid premiums in respect of that Vessel only; 

  

	 	(iv)	they will issue a letter of undertaking in the current LIBA form (in the case of Lloyds brokers), in the form provided for in the Insurances Assignment (in the case of non-Lloyds
brokers and insurers other than clubs) or in their current standard form (in the case of clubs); 

  

	 	(v)	they will accept endorsement of a loss payable clause on the policies in the form provided for in the Insurances Assignment (in the case of brokers and insurers other than clubs) or
will note the interest of the Facility Agent in the entry for the Vessel by way of a loss payable clause in their current standard form (in the case of clubs); and 

  

					
	 	 	97	 	21 July 2005

	 	(vi)	they are not aware of any mortgage, charge, assignment or other encumbrance affecting the Obligatory Insurances with which they are concerned (other than any previously disclosed by
the Borrower to the Facility Agent in writing). 

  

	(d)	Confirmation from the Facility Agent of its satisfaction with a final insurance report prepared by Marsh Insurance Brokers. 

  

	(e)	Confirmation from the Facility Agent of its receipt of a Valuation of the Vessel showing the Initial Market Value of that Vessel. 

  

	6.	Other Requirements 

  

	(a)	Evidence satisfactory to the Facility Agent that the Borrower has successfully completed an IPO. 

  

	7.	Legal opinions 

  

	(a)	A legal opinion of Allen & Overy LLP, London office, English legal advisors to the Lenders, addressed to the Facility Agent as agent for and on behalf of itself and the Lenders.

  

	(b)	A legal opinion of Allen & Overy LLP, Hong Kong office, Hong Kong legal advisors to the Facility Agent, addressed to the Facility Agent as agent for and on behalf of itself and
the Lenders. 

  

	(c)	A legal opinion of Seward & Kissel LLP, Marshall Island legal advisors to the Facility Agent, addressed to the Facility Agent as agent for and on behalf of itself and the
Lenders. 

  

	(d)	A legal opinion of Zhonglun Law Firm, Chinese legal advisors to the Lenders, addressed to the Facility Agent as agent for and on behalf of itself and the Lenders (to be provided
only where the Drawing includes a Loan for a Vessel on charter to CSCL). 

  

	(e)	[A legal opinion of Allen & Overy LLP, Amsterdam office, Dutch legal advisors to the Lenders, addressed to the Facility Agent as agent for and on behalf of itself and the
Lenders in respect of the Retention Account Charge] [(to be provided at the time of the initial Tranche A Request only)]. 

  

	8.	Other Requirements 

  

	*	Each certified copy document must be certified by a director, officer or duly authorised attorney of the Borrower as being true and complete as at a date no earlier than the date of
the Request for a Drawing. 

  

					
	 	 	97	 	21 July 2005

 PART 2 
  
 TRANCHE B INITIAL CONDITIONS PRECEDENT DOCUMENTS 
  

	1.	Borrower 

  

	(a)	A certified copy* of the constitutional documents of the Borrower or, if the Facility Agent already has a copy, a certificate of the Borrower certifying that the copy in the
Facility Agent’s possession is still correct, complete and in full force and effect as at a date no earlier than the date of the Request together with an up to date Certificate of Goodstanding dated no more than ten (10) Business Days prior to
the first Utilisation Date. 

  

	(b)	A certified copy* of a resolution of the board of directors of the Borrower (unless such resolution in relation to the issues below is still in full force and effect):

  

	 	(i)	approving the terms of, and the transactions contemplated by, each Finance Document and each Related Contract to which the Borrower is a party and resolving that it executes each
such Finance Document and each Related Contract, then to be executed; 

  

	 	(ii)	authorising a specified person or persons to execute each Finance Document and each Related Contract on its behalf to which it is a party, then to be executed; and

  

	 	(iii)	authorising a specified person or persons, on its behalf, to sign and/or despatch all other documents and notices to be signed and/or despatched by it under or in connection with
each Finance Document and each Related Contract to which it is a party, then to be executed. 

  

	(c)	A specimen of the signature of each person authorised by the resolution referred to in paragraph 1(b) above. 

  

	(d)	A certified copy* of all other resolutions, consents, licences, exemptions and filings, corporate, official or otherwise which the Lender may reasonably require in connection with
this Agreement or any other Finance Document. 

  

	2.	Finance Documents and Related Contracts 

  

	(a)	A duly executed original of this Agreement. 

  

	(b)	A duly executed original of each Time Charter and Earnings Assignment relating to each Vessel the subject of a Drawing under a Tranche B Loan. 

  

	(c)	A duly executed original of the relevant Mortgage relating to each Vessel the subject of a Drawing under a Tranche B Loan; 

  

	(d)	A duly executed original of the relevant Deed of Covenants relating to each Vessel the subject of a Drawing under a Tranche B Loan; 

  

	(e)	A duly executed original of the Insurances Assignment relating to each Vessel the subject of a Drawing under a Tranche B Loan; 

  

	(f)	A duly executed original of each of the Manager’s Undertakings relating to each Vessel the subject of a Drawing under a Tranche B Loan; 

  

	(g)	A duly executed original of the relevant Swap Agreement; 

  

					
	 	 	1	 	21 July 2005

	(h)	A duly executed original of the Swap Mortgage relating to each Vessel the subject of a Drawing under a Tranche B Loan; 

  

	(i)	A duly executed original of the Swap Deed of Covenants relating to each Vessel the subject of a Drawing under a Tranche B Loan; 

  

	(j)	A certified copy* of each Time Charter (including the documentation by which the benefit and burden of such Time Charter has been transferred to the Borrower from the Original
Owner), duly executed. 

  

	(k)	A certified copy* of the documentation pursuant to which each Vessel the subject of a Drawing under a Tranche B Loan has been sold to the Borrower. 

  

	(l)	Duly executed originals of all notices of assignment required to be served under each Security Document referred to above and faxed copies of the acknowledgements thereof (where it
is not possible to provide originals of the same, with such originals to follow as soon as practicable after the first Utilisation Date), duly executed by each relevant counterparty. 

  

	3.	Other documents 

  

	(a)	A copy of any other authorisation or other document, opinion or assurance which the Facility Agent considers to be necessary or desirable in connection with the entry into and
performance of, and the transactions contemplated by, any Finance Document or any Related Contract or for the validity and enforceability of any Finance Document or any Related Contract. 

  

	(b)	A letter from Clifford Chance Secretaries Limited agreeing to its appointment as process agent for the Borrower under the Finance Documents. 

  

	(c)	A letter from China Shipping (UK) Agency Co., Ltd. or [CP Ships Services Inc.], as appropriate, agreeing to its appointment as process agent for CSCL or Lykes (as appropriate) in
respect of the acknowledgement of the relevant Time Charter and Earnings Assignment. 

  

	4.	The Vessel to be delivered 

  

	(a)	A certified copy* of: 

  

	 	(i)	a classification certificate in respect of the Vessel showing the Vessel to be in class without recommendation, condition or qualification or, in the event that this is not
available, a faxed copy with a certified copy to follow as soon as practicable after, in respect of the Delivered Vessels, the date of this Agreement or, in respect of a Subsequent Vessel, the relevant Delivery Date; 

  

	 	(ii)	a valid Interim Safety Management Certificate for the Vessel; 

  

	 	(iii)	a valid Document of Compliance; and 

  

	 	(iv)	a valid International Ship Security Certificate for the Vessel. 

  

	(b)	Evidence acceptable to the Facility Agent that immediately following the relevant Drawing the Vessel will be delivered to the Borrower (whether under the relevant Shipbuilding
Contract or otherwise) and title (as described in paragraph 1(a)(ii) of Schedule 3) to the Vessel will pass to the Borrower. 

  

					
	 	 	2	 	21 July 2005

	5.	Insurance 

  

	(a)	A certified copy of all current insurance policies in respect of the Vessel. 

  

	(b)	A duly executed and, where necessary, notarised notice of assignment (and acknowledgement of the same) of the Obligatory Insurances in respect of the Vessel duly executed by the
Borrower substantially in the form provided for in the Insurances Assignment. 

  

	(c)	Fax confirmation from each broker, insurer and club concerned with the Obligatory Insurances of the Vessel that: 

  

	 	(i)	the relevant cover is in effect; 

  

	 	(ii)	they will accept notice of assignment of the Obligatory Insurances in favour of the Facility Agent and execute an acknowledgement of the notice in the form required by the Facility
Agent; 

  

	 	(iii)	they will restrict their lien for unpaid premiums under any fleet policy to unpaid premiums in respect of that Vessel only; 

  

	 	(iv)	they will issue a letter of undertaking in the current LIBA form (in the case of Lloyds brokers), in the form provided for in the Insurances Assignment (in the case of non-Lloyds
brokers and insurers other than clubs) or in their current standard form (in the case of clubs); 

  

	 	(v)	they will accept endorsement of a loss payable clause on the policies in the form provided for in the Insurances Assignment (in the case of brokers and insurers other than clubs) or
will note the interest of the Facility Agent in the entry for the Vessel by way of a loss payable clause in their current standard form (in the case of clubs); and 

  

	 	(vi)	they are not aware of any mortgage, charge, assignment or other encumbrance affecting the Obligatory Insurances with which they are concerned (other than any previously disclosed by
the Borrower to the Facility Agent in writing). 

  

	(d)	Confirmation from the Facility Agent of its satisfaction with a final insurance report prepared by Marsh Insurance Brokers. 

  

	(e)	Confirmation from the Facility Agent of its receipt of a Valuation of the Vessel showing the Initial Market Value of that Vessel. 

  

	6.	Other Requirements 

  

	(a)	Evidence satisfactory to the Facility Agent that the Borrower has successfully completed an IPO. 

  

	(b)	The aggregate principal amount of the outstanding Tranche A Loans and Tranche B Loans does not exceed 55 per cent. of the current aggregate Market Value of the Vessels which have
been delivered as at that date. 

  

	7.	Legal opinions 

  

	(a)	A legal opinion of Allen & Overy LLP, London office, English legal advisors to the Lenders, addressed to the Facility Agent as agent for and on behalf of itself and the Lenders.

  

	(b)	A legal opinion of Allen & Overy LLP, Hong Kong office, Hong Kong legal advisors to the Facility Agent, addressed to the Facility Agent as agent for and on behalf of itself and
the Lenders. 

  

					
	 	 	3	 	21 July 2005

	(c)	A legal opinion of Seward & Kissel LLP, Marshall Island legal advisors to the Facility Agent, addressed to the Facility Agent as agent for and on behalf of itself and the
Lenders. 

  

	(d)	A legal opinion of [•], legal advisors to the Lenders in the jurisdiction of the relevant Charterer of the Vessel, addressed to the Facility Agent as agent for and on behalf of
itself and the Lenders. 

  

	8.	Other Requirements 

  

	*	Each certified copy document must be certified by a director, officer or duly authorised attorney of the Borrower as being true and complete as at a date no earlier than the date of
the Request for a Drawing. 

  

					
	 	 	4	 	21 July 2005

 SCHEDULE 3 
  

CONDITIONS SUBSEQUENT TO DRAWING 
  
 The Facility Agent shall require the following documentation and evidence from the Borrower, in respect of a Vessel at the time provided for in Clause 3.1 (d).

  

	1.	 

  

	(a)	Evidence that: 

  

	 	(i)	the Mortgage and the Swap Mortgage in respect of the Vessel have been duly recorded in the [Hong Kong Shipping Register] and constitutes a first priority security interest over the
Vessel and that all taxes and fees payable to the [Hong Kong Shipping Register] in respect of that Vessel have been paid in full; 

  

	 	(ii)	the title to the Vessel is held by the Borrower free of all Security Interests other than Permitted Liens; and 

  

	 	(iii)	the Vessel is provisionally registered in the name of the Borrower, as appropriate, as a [Hong Kong] flag ship at the port of [Hong Kong] 

  

	(b)	In respect of a Subsequent Vessel or an Additional Vessel, confirmation acceptable to the Facility Agent that the Charterer has accepted the Vessel pursuant to the terms of the
relevant Time Charter. 

  

					
	 	 	5	 	21 July 2005

 SCHEDULE 4 
  

PAYMENTS 
  
 PART 1 
  
 FORM OF REQUEST 
  

	To:	Fortis Capital Corp. as Facility Agent 

  

	From:	[The Borrower] 

  

	Date:	[                    ] 

  

	    	  US$1,000,000,000 Credit Agreement dated                      2005
(the Credit Agreement) 

  

					
	 1.
	    	 We        wish to borrow a Drawing under a Loan from you as
follows:

			
	 (a)
	    	Utilisation Date:	  	[            ]
			
	 (b)
	    	Amount/currency:	  	[            ]
	
	 Loan 1/Loan 2/Loan 3/Loan 4/Loan 5/ Loan 6/Loan 7/Loan 8/Loan 9/Loan 10/ Loan 11/Loan 12/Loan
13/Loan 14 *
  

	 2.
	    	Term:                          [           
 ]
			
	 3.
	    	Payment Instructions:	  	 
		
	 	    	 To include provisions that:

	
 *  Delete as
appropriate.

		
	 4.
	    	We confirm that each condition specified in Clause 3.2 (Further conditions precedent) of the Credit Agreement is satisfied on the date of this Request.

  

			
	By:
	
	  

	BORROWER
	
	Authorised Signatory

  

					
	 	 	6	 	21 July 2005

 PART 2 
  
 PAYMENT ADVICE 
  

	To:	[The Borrower] 

  

	From:	Fortis Capital Corp. as Facility Agent 

  

	Date:	[            ] 

  
 US$1,000,000,000 Credit Agreement dated
                    , 2005 
  
 Further to receipt of your request dated [    ] and attached hereto requesting the advance of a Drawing under a Loan, we confirm that all amounts have
been advanced in accordance with the requirements of the attached Request. 
  

					
	 	 	7	 	21 July 2005

 SCHEDULE 5 
  

CALCULATION OF THE MANDATORY COST 
  

	1.	General 

  
 The Mandatory Cost is the weighted average of the rates calculated below by the Facility Agent on the first day of a Term. The Facility Agent must
distribute each amount of Mandatory Cost among the Lenders on the basis of the rate for each Lender. 
  

	2.	For a Lender lending from a Facility Office in the U.K. 

  

	(a)	The relevant rate for a Lender lending from a Facility Office in the U.K. is the arithmetic mean of the rates notified by each of the Reference Banks to the Facility Agent and
calculated in accordance with the following formulae: 

  
 

 
  
 where on the day of application of
the formula: 
  

	 	E	is the charge payable by the Reference Bank to the Financial Services Authority under the fees rules (but, for this purpose, calculated by the Facility Agent on a notional basis as
being the average of the fee tariffs within fee-block Category A1 (Deposit acceptors) of the fees rules, applying any applicable discount and ignoring any minimum fee required under the fees rules) and expressed in pounds per £1 million of the
tariff base of that Reference Bank. 

  

	(b)	For the purposes of this paragraph 2: 

  

	 	(i)	eligible liabilities and special deposit have the meanings given to them at the time of application of the formula by the Bank of England; 

  

	 	(ii)	fees rules means the then current rules on periodic fees in the Supervision Manual of the FSA Handbook; and 

  

	 	(iii)	tariff base has the meaning given to it in the fees rules. 

  

	(c)	Each rate calculated in accordance with a formula is, if necessary, rounded upward to four decimal places. 

  

	(d)      (i)	Each Reference Bank must supply to the Facility Agent the information required by it to make a calculation of the rate for that Reference Bank. The Facility Agent may assume that
this information is correct in all respects. 

  

	 	(ii)	If a Reference Bank fails to do so, the Facility Agent may assume that the Reference Bank’s obligations in respect of cash ratio deposits, special deposits and the fees rules
are the same as those of a typical bank from its jurisdiction of incorporation with a Facility Office in the same jurisdiction as its Facility Office. 

  

	 	(iii)	The Facility Agent has no liability to any Party if its calculation over or under compensates any Lender. 

  

					
	 	 	8	 	21 July 2005

	3.	For a Lender lending from a Facility Office in a Participating Member State 

  

	 	(a)	The relevant rate for a Lender lending from a Facility Office in a Participating Member State is the percentage rate per annum notified by that Lender to the Facility Agent as its
cost of complying with the minimum reserve requirements of the European Central Bank. 

  

	 	(b)	If a Lender fails to specify a rate under paragraph (a) above, the Facility Agent will assume that the Lender has not incurred any such cost. 

  

	3.	Changes 

  
 The Facility Agent may, after consultation with the Borrower and the Lenders, notify all the Parties of any amendment to this Schedule which is required
to reflect: 
  

	 	(i)	any change in law or regulation; or 

  

	 	(ii)	any requirement imposed by the Bank of England, the Financial Services Authority or the European Central Bank (or, in any case, any successor authority). 

 
 Any notification will be, in the absence of manifest error, conclusive
and binding on all the Parties. 
  

					
	 	 	9	 	21 July 2005

 SCHEDULE 6 
  

FORM OF TRANSFER CERTIFICATE 
  

			
	 To:
	  	The Borrower
		
	 From:
	  	[THE EXISTING BANK] and [THE NEW BANK]
		
	 Date:
	  	[            ]

  
 US$1,000,000,000
Credit Agreement dated                         , 2005 (the Credit Agreement) 
  
 We refer to Clause 28.3 (Procedure for transfer by way of novations) of the Credit Agreement.

  

	1.	We [             ] (the Existing Bank) and
[             ] (the New Bank) agree to the Existing Bank and the New Bank novating all the Existing Bank’s rights and obligations referred to in the Schedule in accordance with
Clause 28.3. (Procedure for transfer by way of novations). 

  

	2.	The specified date for the purposes of Clause 28.3(a) (Procedure for transfer by way of novations) is [date of novation]. 

  

	3.	The Facility Office and address for notices of the New Bank for the purposes of Clause 34.2 (Contact details) are set out in the Schedule attached to this Certificate.

  

	4.	This Novation Certificate is governed by English law. 

  

					
	 	 	10	 	21 July 2005

 THE SCHEDULE 
  
 Rights and obligations to be novated 
  
 [Choose one of the following options (a) to (d):] 
  

	(a)	all of the rights and obligations of the Existing Lender in respect of the Facility - principal amount US$[            
]. 

  

	(b)	all of the rights and obligations of the Existing Lender in respect of Vessel Loan [            ] [and Vessel Loan
[            ]] - principal amount US$[            ]. 

  

	(c)	the principal amount of US$[            ] in respect of each of the Loans and all the rights and obligations attached to
the same-total principal amount US$[            ]. 

  

	(d)	the principal amount of US$[            ] in respect of [each of] Vessel Loan
[            ] [and Vessel Loan [            ] and [            ]]
and all the rights and obligations attached to the same. 

  
 [New
Bank] 
  
 [Facility Office Address for notices] 
  
  

			
	 [Existing Bank]
	  	[New Bank]
		
	 By:
	  	By:
		
	 Date:
	  	Date:

  
 The Transfer Date is confirmed by the
Facility Agent as [            ]. 
  
 FORTIS CAPITAL CORP. 
  
 By: 
  

					
	 	 	11	 	21 July 2005

 SCHEDULE 7 
  

REPAYMENT SCHEDULE 
  

					
	 	 	12	 	21 July 2005

 SCHEDULE 8 
  

COMPLIANCE CERTIFICATE 
  

	To:	Fortis Capital Corp. as Facility Agent 

  
 From:    [Borrower] 
  
 US$1,000,000,000 Credit Agreement dated             , 2005 (the Credit Agreement)

  

	1.	Terms defined in the Credit Agreement have the same meaning in this Certificate. 

  

	2.	I/We hereby certify that as of [ ] the status of the financial covenants set out in Clause 17 (Financial Covenants) of the Credit Agreement are as follows: 

 

	(e)	Tangible Net Worth: the Tangible Net Worth of the Borrower is not less than four hundred and fifty million Dollars (US$450,000,000). 

  

	(f)	Gearing: the Total Borrowings do not exceed 65 per cent. of Total Assets. 

  

	(g)	Net Interest Coverage Ratio: the Interest Coverage Ratio is greater than 2.50 to 1. 

  

	(h)	Interest and Principal Coverage Ratio: the Interest and Principal Coverage Ratio is not less than 1.1 to 1. 

  

	(i)	the aggregate Market Value of the Vessels is not less than 150 per cent. of the aggregate principal amount of the outstanding Loans* 

  

	*	delete if circumstances in Clause 17.8 of the Credit Agreement have not occurred 

  
 [            ] 
  

	
	Yours faithfully,
	
	[                                      
                                        
      ]
	Chief Executive Officer
	
	[or]
	
	_________________________________________
	Chief Financial Officer

  

					
	 	 	13	 	21 July 2005

 SCHEDULE 9 
  

ANNUAL COMPLIANCE CERTIFICATE 
  

	To:	Fortis Capital Corp. as Facility Agent 

  

	From:	[Borrower] 

  
 US$1,000,000,000 Credit Agreement dated                     , 2005 (the Credit Agreement) 

 

	1.	Terms defined in the Credit Agreement have the same meaning in this Certificate. 

  

	2.	I/We hereby certify that [no Default has occurred and is continuing or is outstanding] [a Default under Clause
[            ] of [specify document] is outstanding and the following steps are being taken to remedy it [            ].

  

	3.	[Except as set out below, the representations set out in Clause 14 (Representations) of the Credit Agreement are deemed to be repeated as at the date hereof.]

  

	4.	I/We hereby attach a list of the estimated dates of the intended dry docking of the Vessels actually delivered on or before the date of this Certificate. 

 

	5.	I/We hereby certify that as of [ ] the status of the financial covenants set out in Clause 17 (Financial Covenants) of the Credit Agreement are as follows: 

 

	(a)	Tangible Net Worth: the Tangible Net Worth of the Borrower is not less than four hundred and fifty million Dollars (US$450,000,000). 

  

	(b)	Gearing: the Total Borrowings do not exceed 65 per cent. of Total Assets. 

  

	(c)	Net Interest Coverage Ratio: the Interest Coverage Ratio is greater than 2.50 to 1. 

  

	(d)	Interest and Principal Coverage Ratio: the Interest and Principal Coverage Ratio is not less than 1.1 to 1. 

  

	(e)	the aggregate Market Value of the Vessels is not less than 150 per cent. of the aggregate principal amount of the outstanding Loans* 

  

	*	delete if circumstances in Clause 17.8 of the Credit Agreement have not occurred 

  
 [            ] 
  

	
	 Yours faithfully,

	
	 [                                      
                                        
  ]

	 Chief Executive Officer

	
	 [or]

	
	 ________________________________________

	 Chief Financial Officer

  

					
	 	 	14	 	21 July 2005

 SCHEDULE 10 
  
 MANAGER’S CERTIFICATE 
  

	To:	Fortis Capital Corp. as Facility Agent 

  

	From:	[Manager] 

  
 US$1,000,000,000 Credit Agreement dated                     , 2005 (the Credit Agreement) 

 

	6.	Terms defined in the Credit Agreement have the same meaning in this Certificate. 

  

	7.	I/We hereby confirm that on the date of this Certificate [Manager] has sufficient funds to meet all of its obligations under the Management Agreement. 

  
 [            ]

  
 Yours faithfully, 
  
 [                                      
                                        
  ] 
 Chief Executive Officer 
  

					
	 	 	15	 	21 July 2005

 SCHEDULE 11 
  
 ESTIMATED ADDBACK RELATING TO DELIVERED VESSELS DEPRECIATION 
  

			
	 Date

	  	 Amount of
Add Back
 (US$)

	 9/30/05
	  	207,588,000
	 12/31/05
	  	205,843,000
		
	 3/31/06
	  	204,099,000
	 6/30/06
	  	202,354,000
	 9/30/06
	  	200,610,000
	 12/31/06
	  	198,866,000
		
	 3/31/07
	  	197,121,000
	 6/30/07
	  	195,377,000
	 9/30/07
	  	193,632,000
	 12/31/07
	  	191,888,000
		
	 3/31/08
	  	190,143,000
	 6/30/08
	  	188,399,000
	 9/30/08
	  	186,655,000
	 12/31/08
	  	184,910,000
		
	 3/31/09
	  	183,166,000
	 6/30/09
	  	181,42,000 1
	 9/30/09
	  	179,677,000
	 12/31/09
	  	177,932,000
		
	 3/31/10
	  	176,188,000
	 6/30/10
	  	174,443,000
	 9/30/10
	  	172,699,000
	 12/31/10
	  	170,955,000
		
	 3/31/11
	  	169,210,000
	 6/30/11
	  	167,466,000
	 9/30/11
	  	165,721,000
	 12/31/11
	  	163,977,000
		
	 3/30/12
	  	162,232,000
	 6/29/12
	  	160,488,000
	 9/29/12
	  	158,744,000
	 12/30/12
	  	156,999,000
		
	 3/31/2013
	  	255,255,000
	 6/30/2013
	  	153,510,000
	 9/30/2013
	  	151,766,000
	 12/31/2013
	  	150,021,000
		
	 3/31/2014
	  	148,277,000
	 6/30/2014
	  	146,253,000
	 9/30/2014
	  	144,788,000
	 12/31/2014
	  	143,044,000

  

					
	 	 	16	 	21 July 2005

 SCHEDULE 12 
  
 STANDING PAYMENT INSTRUCTIONS 
  

					
	 	 	17	 	21 July 2005

 APPENDIX 1 
  

FORM OF INSURANCES ASSIGNMENT 
  

					
	 	 	18	 	21 July 2005

 APPENDIX 2 
  

FORM OF MORTGAGE 
  

					
	 	 	19	 	21 July 2005

 APPENDIX 3 
  

FORM OF DEED OF COVENANTS 
  

					
	 	 	20	 	21 July 2005

 APPENDIX 4 
  

FORM OF MANAGEMENT AGREEMENT ASSIGNMENT 
  

					
	 	 	21	 	21 July 2005

 APPENDIX 5 
  

FORM OF SWAP MORTGAGE 
  

					
	 	 	22	 	21 July 2005

 APPENDIX 6 
  

FORM OF SWAP DEED OF COVENANTS 
  

					
	 	 	23	 	21 July 2005

 APPENDIX 7 
  

FORM OF SWAP AGREEMENT ASSIGNMENT 
  

					
	 	 	24	 	21 July 2005

 APPENDIX 8 
  

FORM OF DEED OF PROCEEDS AND PRIORITIES 
  

					
	 	 	25	 	21 July 2005

 APPENDIX 9 
  

FORM OF CHARTER GUARANTEE ASSIGNMENT 
  

					
	 	 	26	 	21 July 2005

 SIGNATORIES 
  
 Borrower 
  
 SEASPAN CORPORATION 
  
 By: 
  
 Original Lenders 
  
 CITIBANK, N.A. 
  
 By: 
  
 CREDIT SUISSE 
  
 By: 
  
 DNB NOR BANK ASA 
  
 By: 
  

FORTIS CAPITAL CORP. 
  
 By: 
  
 LANDESBANK HESSEN-THÜRINGEN

  
 By: 
  
 The Arrangers 
  
 CITIGROUP GLOBAL MARKETS LIMITED 
  
 By: 
  
 FORTIS CAPITAL CORP. 
  
 By: 
  

					
	 	 	27	 	21 July 2005

	
	The Facility Agent
	
	FORTIS CAPITAL CORP.
	
	By:

  

					
	 	 	28	 	21 July 2005Asset Purchase Agreement

 Exhibit 10.9 
  
 ASSET PURCHASE AGREEMENT 
  
 Dated for reference                     , 2005

  
 Among 
  
 SEASPAN CORPORATION 
  
 as Purchaser 
  
 and 
  
 THE PARTIES LISTED ON SCHEDULE 1 
  
 as Vendors 
  
 and 
  
 SEASPAN CONTAINER LINES LIMITED 

  
 TABLE OF CONTENTS

  

					
	 1.       INTERPRETATION
	  	2
			
	 1.1
	  	Definitions	  	2
	 1.2
	  	Construction and Interpretation	  	7
	 1.3
	  	Business Day	  	8
	 1.4
	  	Governing Law	  	8
	 1.5
	  	Time of Essence	  	8
	 1.6
	  	Schedules	  	8
		
	 2.       PURCHASE OF ASSETS
	  	8
			
	 2.1
	  	Initial Purchased Assets	  	8
	 2.2
	  	Subsequent Purchased Assets	  	9
	 2.3
	  	Closing of Initial Assets	  	9
	 2.4
	  	Closing of Subsequent Assets	  	9
	 2.5
	  	Place of Closing	  	10
	 2.6
	  	Assignment and Transfer Documents	  	10
	 2.7
	  	Assumption of Time Charters	  	11
	 2.8
	  	Excluded Liabilities	  	11
		
	 3.       PURCHASE PRICE
	  	12
			
	 3.1
	  	Initial Purchase Price	  	12
	 3.2
	  	Allocation of Initial Purchase Price	  	12
	 3.3
	  	Payment of Initial Purchase Price	  	12
	 3.4
	  	Subsequent Purchase Price	  	13
	 3.5
	  	Allocation of Subsequent Purchase Price	  	13
	 3.6
	  	Payment of the Subsequent Purchase Price	  	13
	 3.7
	  	Closing Date Purchase Price Adjustments	  	14
	 3.8
	  	Shipyard Deficient Vessel	  	15
	 3.9
	  	Rebates Pursuant to Ship Building Contracts	  	15
	 3.10
	  	Risk of Loss	  	16
	 3.11
	  	Total Loss	  	16
	 3.12
	  	Transfer Taxes	  	16
	 3.13
	  	Letter of Credit	  	16
		
	 4.       REPRESENTATIONS AND WARRANTIES
	  	17
			
	 4.1
	  	Representations and Warranties of the Vendors	  	17
	 4.2
	  	Representations and Warranties of the Purchaser	  	19
	 4.3
	  	Representations and Warranties of SCLL	  	19
		
	 5.       PRE-CLOSING MATTERS
	  	20
			
	 5.1
	  	Covenants of the Vendors Prior to Closing	  	20
	 5.2
	  	Covenants of the Purchaser Prior to Closing	  	21
	 5.3
	  	Provisions in Respect of Time Charters and Ship Building Contracts	  	21

					
	 5.4
	  	Delivery of Vessel Sale Agreement	  	22
		
	 6.       CONDITIONS OF CLOSING
	  	22
			
	 6.1
	  	Conditions of the Purchaser	  	22
	 6.2
	  	Conditions of the Vendors	  	24
	 6.3
	  	Actions to Satisfy Closing Conditions	  	25
		
	 7.       POST-CLOSING COVENANTS
	  	25
			
	 7.1
	  	Exercise Under Ship Building Contracts	  	25
	 7.2
	  	Post-Delivery Obligations	  	25
	 7.3
	  	Covenants of SCLL	  	26
		
	 8.       SURVIVAL OF REPRESENTATIONS AND RECOURSE
	  	26
			
	 8.1
	  	Survival of Representations, Warranties and Covenants of the Vendors	  	26
	 8.2
	  	Survival of Representations, Warranties and Covenants of the Purchaser	  	27
	 8.3
	  	Survival of Representations, Warranties and Covenants of SCLL	  	27
	 8.4
	  	Reliance	  	28
	 8.5
	  	Indemnity by the Vendors	  	28
	 8.6
	  	Indemnity by the Purchaser	  	29
	 8.7
	  	Indemnity by SCLL	  	29
	 8.8
	  	Defence of Third Party Claims	  	30
	 8.9
	  	Limitations on Amount	  	31
	 8.10
	  	Election	  	31
		
	 9.       TERMINATION AND WAIVER
	  	32
			
	 9.1
	  	Termination for Failure to Consummate Initial Public Offering	  	32
	 9.2
	  	Termination Upon Termination of a Vessel Sale Agreement	  	32
	 9.3
	  	Effect of Waiver	  	32
	 9.4
	  	Without Prejudice	  	32
		
	 10.     MISCELLANEOUS
	  	32
			
	 10.1
	  	Notices	  	32
	 10.2
	  	Further Assurances	  	33
	 10.3
	  	Entire Agreement	  	34
	 10.4
	  	Assignment	  	34
	 10.5
	  	Waiver and Amendment	  	34
	 10.6
	  	Severability	  	34
	 10.7
	  	Third Party Beneficiaries	  	35
	 10.8
	  	Submission to Jurisdiction	  	35
	 10.9
	  	Dispute Resolution	  	35
	 10.10
	  	Counterparts	  	35
	 10.11
	  	Enurement	  	36

  

 ii 

  
 ASSET PURCHASE AGREEMENT

  
 THIS AGREEMENT is dated for reference
                    , 2005. 
  
 BETWEEN: 
  
 THE PARTIES LISTED ON SCHEDULE 1 
  
 (collectively, the “Vendors” and each a “Vendor”) 
  
 AND: 
  
 SEASPAN CORPORATION, a corporation formed under the laws of the Marshall Islands 
  
 (the “Purchaser”) 
  
 AND: 
  
 SEASPAN CONTAINER LINES LIMITED, a corporation formed under the laws of the Republic of Cyprus 
  
 (“SCLL”) 
  
 WHEREAS: 
  
 A. Each of the Vendors listed on Schedule 1A (collectively, the “Initial Vendors”) is the registered owner of the vessel set forth opposite that Initial Vendor’s name on Schedule 1A hereto (collectively, the
“Delivered Vessels”); 
  
 B. Each of the Vendors listed on
Schedule 1B (collectively, the “Subsequent Vendors”) is party to a shipbuilding contract for the construction and delivery of the vessel set forth opposite that Subsequent Vendor’s name on Schedule 1B hereto (collectively, the
“Outstanding Vessels”); 
  
 C. Each Vendor is party to the
long-term, fixed-rate time charter set forth opposite that Vendor’s name on Schedule 1C hereto (collectively, the “Time Charters”) with respect to the Delivered Vessel or Outstanding Vessel, as the case may be, also set forth
opposite that Vendor’s name on Schedule 1C hereto; 
  
 D. The Purchaser
wishes to purchase and the Vendors wish to sell and transfer to the Purchaser, or assign to the Purchaser, as the case may be, the Delivered Vessels, the Outstanding Vessels and the Time Charters, together with certain other assets related thereto,
all upon and subject to the conditions herein contained; and 
  
 E. Each of the
Vendors is wholly owned by Seaspan Container Lines Limited. 

  
 THIS AGREEMENT WITNESSES that in
consideration of the respective covenants, agreements, representations, warranties and indemnities of the Parties herein contained and for other good and valuable consideration (the receipt and sufficiency of which are acknowledged by each Party),
the Parties agree as follows: 
  

	1.	INTERPRETATION 

  

	1.1	Definitions 

  
 In this Agreement, unless the context requires otherwise or unless otherwise specifically provided herein, the following terms shall have the respective meanings set out below and grammatical variations of such terms
shall have corresponding meanings: 
  
 “Affiliate” means, with respect to any Person, any other Person that, directly or indirectly, through one or more intermediaries Controls, is Controlled by or is under common Control with, the Person in question;

  
 “Agreement” means this Agreement, including
its recitals and schedules, as amended and supplemented; 
  
 “Applicable Law” in respect of any Person, property, transaction or event, means all laws, statutes, ordinances, regulations, municipal by-laws, treaties, judgments and decrees applicable to that Person, property,
transaction or event and, whether or not having the force of law, all applicable official directives, rules, consents, approvals, authorizations, guidelines, orders, codes of practice and policies of any Governmental Authority having or purporting
to have authority over that Person, property transaction or event and all general principles of common law and equity; 
  
 “Builder” means, in respect of any Vessel, Samsung Heavy Industries Co. Ltd., and any successor or permitted assign thereof; 

 
 “Business Day” means any day other than a Saturday,
Sunday or any statutory holiday on which banks in the Republic of Cyprus, Hong Kong, the Province of British Columbia or the Marshall Islands are required to close; 
  
 “Change of Control” has, with respect to the Purchaser, the meaning ascribed to such term in the Management
Agreement; 
  
 “Charter Prepayment” means, with
respect to any Initial Vendor, an amount paid by or on behalf of the charterer under that Initial Vendor’s Time Charter in respect of a period of time after the Initial Time of Closing; 
  
 “Closing Date” means, in respect of the Initial Assets, the
day of the Initial Closing and in respect of any Subsequent Assets the day of the Subsequent Closing of those Subsequent Assets; 
  
 “Common Shares” means the Class A common shares in the capital of the Purchaser; 
  
 “Control” or “Controlled” means, with
respect to any Person, the right to elect or appoint, directly or indirectly, a majority of the directors of such Person or a majority of the Persons who have the right, including any contractual right, to manage and direct the business, affairs and

  

 2 

 
operations of such Person, or the possession of the power to direct or cause the direction of the management and policies of a Person, whether through
ownership of voting securities, by contract, or otherwise; 
  
 “Credit Facility” means the US$1,000,000,000 credit facility agreement dated the date hereof between the Purchaser, Citigroup Global Markets Limited, Fortis Capital Corp. and various banks and other financial institutions
thereto; 
  
 “Default” means a material Event of
Default under and as defined in the Credit Facility that is not capable of remedy or, if capable of remedy has not been cured by the Purchaser within the applicable cure period, but excludes any Event of Default that is determined to have been
caused by the Manager; for the purposes of this definition, a “material Event of Default” means any Event of Default the effect of which is to prohibit or prevent the Purchaser from (i) paying dividends or (ii) borrowing, pursuant to the
Credit Facility, those funds required to complete its obligations under this Agreement; 
  
 “Delivered” means, in respect of any Outstanding Vessel, the concurrent delivery by the Subsequent Vendor of that Outstanding Vessel and the Builder thereof, to each other, of a protocol of acceptance
and delivery acknowledging, the delivery of that Outstanding Vessel by the Builder, and the acceptance thereof by that Subsequent Vendor; 
  
 “Delivered Vessels” has the meaning given to it in the recitals; 
  
 “Delivery Date” means, with respect to any Outstanding Vessel, the date that Outstanding Vessel is
Delivered to the Subsequent Vendor set out across from that Outstanding Vessel on Schedule 1B hereto; 
  
 “Encumbrance” means any mortgage, lien, charge, assignment, adverse claim, hypothec or encumbrance, whether fixed or floating, on, or any
security interest in, any property, whether real, personal or mixed, tangible or intangible, any pledge or hypothecation of any property, any deposit arrangement, priority, conditional sale agreement, other title retention agreement or equipment
trust, capital lease or other security arrangements of any kind; 
  
 “Excluded Assets” means any container lashing gear, lube oils, spares and stores aboard a Vessel; 
  
 “Existing Credit Facilities” means the various credit agreements between each of the Vendors and certain financial institutions as listed
in Schedule 1.1A; 
  
 “Existing Credit Facilities
Security” means the encumbrances, mortgages, charges, liens, swap agreements and other security provided pursuant to or in connection with the Existing Credit Facilities; 
  
 “Financial Statements” means the financial statements prepared in accordance with GAAP for each Vendor, as
of December 31, 2004 and for the year then ended, together with the auditor’s report thereon; 
  

 3 

 “GAAP” means generally accepted accounting principles consistently applied in the United
States of America; 
  
 “Governmental Authority”
means any domestic or foreign government, including federal, provincial, state, municipal, county or regional government or governmental or regulatory authority, domestic or foreign, and includes any department, commission, bureau, board,
administrative agency or regulatory body of any of the foregoing and any multinational or supranational organization; 
  
 “Indemnified Party” has the meaning given to it in Section 8.8; 
  
 “Indemnifier” has the meaning given to it in Section 8.8; 
  
 “Indemnity Claim” has the meaning given to it in Section
8.8; 
  
 “Initial Assets” has the meaning given
to it in Section 2.1; 
  
 “Initial Closing” has
the meaning given to it in Section 2.3; 
  
 “Initial
Effective Time” has the meaning given to it in Section 2.3; 
  
 “Initial Public Offering” means the initial public offering of the Purchaser’s Class A common shares pursuant to the Purchaser’s Registration Statement on Form F-1; 
  
 “Initial Purchase Price” has the meaning given to it in
Section 3.1; 
  
 “Initial Time of Closing” has
the meaning given to it in Section 2.3; 
  
 “Initial
Vendors” has the meaning given to it in the recitals; 
  
 “ISM Code” means the International Safety Management Code of the Safe Operating of Ships and for Pollution Prevention constituted pursuant to Resolution A 741(18) of the International Maritime Organization and incorporated
into the Safety of Life at Sea Convention; 
  
 “Losses” means, with respect to any matter, all losses, claims, damages, liabilities, deficiencies, costs, expenses (including all costs of investigation, legal and other professional fees and disbursements, interest,
penalties and amounts paid in settlement) or diminution of value, whether or not involving a claim from a third party, however specifically excluding consequential, special and indirect losses, loss of profit and loss of opportunity; 
  
 “Management Agreement” means a management agreement
between, among others, the Company and the Manager; 
  
 “Manager” means Seaspan Management Services Limited; 
  
 “Notice” means any notice, citation, directive, order, claim, litigation, investigation, proceeding, judgment, letter or other communication, written or oral, actual or threatened, from any Person;

  

 4 

 “Omnibus Agreement” means the omnibus agreement, dated as of the date hereof, between,
among others, the Company and the Manager; 
  
 “Outstanding Vessels” has the meaning given to it in the recitals; 
  
 “Parties” means all parties to this Agreement and “Party” means any one of them; 
  
 “Permitted Action” means any suit, action, or other proceeding in any way related to or arising out of this Agreement commenced in the
courts of British Columbia and all courts having appellate jurisdiction over those courts, by any party to this Agreement against any other party to this Agreement; 
  
 “Permitted Encumbrances” means any of the following: 
  

	 	(i)	liens for current taxes or ad valorem taxes not yet due and payable or contested in good faith, if a reserve or other appropriate provision, if any, as may be required by GAAP shall
have been made therefor; 

  

	 	(ii)	statutory and common law liens of carriers, warehousemen, mechanics, suppliers, materialsmen, repairers and other similar liens, including maritime liens imposed by law incurred in
the ordinary course of business for sums not yet due and payable or contested in good faith; 

  

	 	(iii)	liens for master’s disbursements incurred in the ordinary course of trading and unpaid crew’s wages, including wages of the master and stevedores employed by the Vessel,
outstanding in the ordinary course of trading, statutory obligations, surety and appeal bonds, bids, leases, government contracts, performance and return of money bonds and similar obligations, in each case in the ordinary course of business;

  

	 	(iv)	liens incurred in the ordinary course of business arising from vessel chartering, drydocking, maintenance, the furnishing of supplies and bunkers to Vessels, repairs and
improvements to Vessels; and 

  

	 	(v)	liens for salvage and general average. 

  
 “Person” means an individual, legal personal representative, corporation, body corporate, firm, partnership, trust, trustee, syndicate,
joint venture, unincorporated organization or Governmental Authority; 
  
 “Post-Delivery Obligations” means those obligations of the Vendor under each Ship Building Contract that arise after a Vessel is Delivered and that directly relate to or are associated with the benefits and rights being
assigned under Section 2.1(d) and 2.2(d) hereof, including with respect to Article VII (6), Article IX (2), Article IX(3) Article IX(9) and Article XV of the Ship Building Contract. 
  
 “Purchased Assets” means, collectively, all of the Initial Assets and all of the Subsequent Assets;

  
 “Purchaser’s Indemnified Persons” has
the meaning given to it in Section 8.5; 
  

 5 

 “Ship Building Contract” means, with respect to each Vendor, the ship building contract
with the Builder set forth across from that Vendor’s name on Schedule 1.1B hereto, and “Ship Building Contracts” means all of such contracts; 
  
 “Subordinated Shares” means the Class B common shares, par value $0.01 per share, in the capital of the
Purchaser; 
  
 “Subsequent Assets” has the
meaning given to it in Section 2.2; 
  
 “Subsequent
Closing” has the meaning given to it in Section 2.4; 
  
 “Subsequent Closing Time” has the meaning given to it in Section 2.4; 
  
 “Subsequent Effective Time” has the meaning given to it in Section 2.4; 
  
 “Subsequent Purchase Price” has the meaning given to it in Section 3.4; 
  
 “Subsequent Vendors” has the meaning given to it in the
recitals; 
  
 “Subsidiary” means, with respect
to any Person, (a) a corporation of which more than 50% of the voting power of shares entitled (without regard to the occurrence of any contingency) to vote in the election of directors or other governing body of such corporation is owned, directly
or indirectly, at the date of determination, by such Person, by one or more corporations Controlled by of such Person or a combination thereof, (b) a partnership (whether general or limited) in which such Person or a corporation Controlled by such
Person is, at the date of determination, a general or limited partner of such partnership, but only if more than 50% of the partnership interests of such partnership (considering all of the partnership interests of the partnership as a single class)
is owned, directly or indirectly, at the date of determination, by such Person, one or more corporations Controlled by such Person, or a combination thereof, or (c) any other Person (other than a corporation or a partnership) in which such Person,
one or more corporations Controlled by such Person, or a combination thereof, directly or indirectly, at the date of determination, has (i) at least a majority ownership interest or (ii) the power to elect or direct the election of a majority of the
directors or other governing body of such Person. 
  
 “Taxes” means all income, franchise, business, property, sales, use, goods and services or value added, withholding, excise, alternate minimum capital, transfer, excise, customs, anti-dumping, stumpage, countervail, net
worth, stamp, registration, franchise, payroll, employment, health, education, business, school, property, local improvement, development, education development and occupation taxes, surtaxes, duties, levies, imposts, rates, fees, assessments, dues
and charges and other taxes required to be reported upon or paid to any domestic or foreign jurisdiction and all interest and penalties thereon; 
  
 “Time Charters” has the meaning given to it in the recitals; 
  
 “Time of Closing” means in respect of any Initial Asset, the Initial Time of Closing and in respect of any
Subsequent Asset, the Subsequent Time of Closing for that Subsequent Asset; 
  

 6 

 “Total Loss” means in relation to a Vessel 
  

	 	(i)	actual, constructive, compromised, agreed or arranged total loss of that Vessel; 

  

	 	(ii)	requisition for title or other compulsory acquisition of that Vessel otherwise than by requisition for hire; and 

  

	 	(iii)	requisition for hire, capture, seizure, arrest, detention, or confiscation of that Vessel by any Governmental Authority or by persons acting or purporting to act on behalf of any
Governmental Authority; 

  
 “Vendors’
Indemnified Persons” has the meaning given to it in Section 8.6; 
  
 “Vendor’s Purchased Assets” means, in respect of an Initial Vendor, that Vendor’s Initial Assets (as described in Section 2.1 hereof) and with respect to a Subsequent Vendor, that
Vendor’s Subsequent Assets (as described in Section 2.2 hereof); 
  
 “Vessel Sale Agreement” has the meaning given to it in Section 2.6; 
  
 “Vessel Warranties” means, in respect of any Vendor, any and all warranties provided to Vendor as purchaser of the Vessel under the relevant Ship Building Contract, including, but not limited to, the
“Warranty of Quality” described in Article IX thereof, any extended guarantee rights contained therein and the guarantee by the paint manufacturer with respect to defects in paint and/or application or underwater parts of the Vessel
delivered or to be delivered under that Vendor’s Ship Building Contract and any other material warranties in respect of the Vessel; and 
  
 “Vessels” means the Delivered Vessels and Outstanding Vessels and “Vessel” means any one of them. 
  

	1.2	Construction and Interpretation 

  
 The division of this Agreement into Sections, the insertion of headings and the provision of a table of contents are for convenience only, do not form a part of this
Agreement and will not be used to affect the construction or interpretation of this Agreement. Unless otherwise specified: 
  

	 	(a)	each reference in this Agreement to “Section” and “Schedule” is to a Section of, and a Schedule to, this Agreement; 

  

	 	(b)	each reference to a statute is deemed to be a reference to that statute, and to the regulations made under that statute, as amended or re-enacted from time to time;

  

	 	(c)	words importing the singular include the plural and vice versa and words importing gender include all genders; 

  

	 	(d)	references to time of day or date mean the local time or date in Vancouver, British Columbia; 

  

	 	(e)	all references to amounts of money mean lawful currency of the United States; and 

  

	 	(f)	the language in all parts of this Agreement will in all cases be construed as a whole and neither strictly for nor strictly against any of the Parties. 

  

 7 

	1.3	Business Day 

  
 If under this Agreement any payment or calculation is to be made, or any other action is to be taken, on or as of a day which is not a Business Day, the payment or calculation is to be made, or that other action is to
be taken, on or as of the next day that is a Business Day. 
  

	1.4	Governing Law 

  
 This Agreement and each of the documents contemplated by or delivered under or in connection with this Agreement are, unless those documents state otherwise, governed exclusively by, and are to be enforced, construed
and interpreted exclusively in accordance with, the laws of British Columbia which are deemed to be the proper law of the Agreement. 
  

	1.5	Time of Essence 

  
 Time is of the essence of this Agreement. 
  

	1.6	Schedules 

  
 The schedules attached to this Agreement, will, for all purposes, form an integral part of the Agreement. 
  
 Whenever disclosure of any matter is made in any Schedule to this Agreement for the purposes of any representation, warranty or other provision of this Agreement, such
disclosure shall be deemed to constitute disclosure in any other Schedule to this Agreement. 
  

	2.	PURCHASE OF ASSETS 

  

	2.1	Initial Purchased Assets 

  
 Each Initial Vendor agrees to sell, assign and transfer to the Purchaser and the Purchaser agrees to purchase from each Initial Vendor for the price and in accordance
with and subject to the terms and conditions set forth in this Agreement, the following: 
  

	 	(a)	all of that Initial Vendor’s right, title and interest in and to the Delivered Vessel set out across from that Initial Vendor’s name on Schedule 1A hereto, but excluding
the Excluded Assets; 

  

	 	(b)	the Time Charter set out across from that Initial Vendor’s name on Schedule 1C hereto, including, but not limited to the right to receive any and all charter hire payments
pursuant thereto accruing on or after the respective Time of Closing, but excluding any rebates or adjustments for charter hire accruing or arising from circumstances existing prior (and not continuing after) to the respective Time of Closing;

  

	 	(c)	that Initial Vendor’s Vessel Warranties, if any, to the extent assignable, and to the extent not assignable, the right to receive the benefit of that Initial Vendor’s
Warranties pursuant to Section 7.1; and 

  

 8 

	 	(d)	all rights and benefits under that Initial Vendor’s Ship Building Contract, to the extent assignable, and to the extent not assignable, the right to receive all benefits
thereunder pursuant to Section 7.1. 

  
 The assets described in
subsection 2.1(a) to 2.1(d), but excluding the Excluded Assets, with respect to all of the Initial Vendors, are hereinafter collectively referred to as the “Initial Assets”. 
  

	2.2	Subsequent Purchased Assets 

  
 Each Subsequent Vendor agrees to sell, assign and transfer to the Purchaser and the Purchaser agrees to purchase from each Subsequent Vendor for the price and in
accordance with and subject to the terms and conditions set forth in this Agreement, the following: 
  

	 	(a)	all of that Subsequent Vendor’s right, title and interest in and to the Outstanding Vessel set out across from that Subsequent Vendor’s name on Schedule 1B hereto, but
excluding the Excluded Assets; 

  

	 	(b)	the Time Charter set out across from that Subsequent Vendor’s name on Schedule 1C hereto, including, but not limited to the right to receive any and all charter hire payments
pursuant to thereto accruing on or after the respective Time of Closing; 

  

	 	(c)	that Subsequent Vendor’s Vessel Warranties, to the extent assignable, and to the extent not assignable, the right to receive the benefit of that Subsequent Vendor’s
Warranties pursuant to Section 7.1; 

  

	 	(d)	all rights and benefits under that Subsequent Vendor’s Ship Building Contract, to the extent assignable, and to the extent not assignable, the right to receive all benefits
thereunder pursuant to Section 7.1. 

  
 The assets described in
subsection 2.2(a) to 2.2(d), but excluding the Excluded Assets, with respect to all of the Subsequent Vendors, are hereinafter collectively referred to as the “Subsequent Assets”. 
  

	2.3	Closing of Initial Assets 

  
 Subject to satisfaction or waiver of the conditions set forth in Sections 6.1 and 6.2, the sale and transfer of all of the Initial Assets and the payment of the Initial
Purchase Price shall take place on a date that is within five (5) Business Days of the closing of the Initial Public Offering, or on such other date as may be agreed upon in writing by the Initial Vendors and the Purchaser (the “Initial Time of
Closing”) with effect as of 12:01 a.m. on such date (the “Initial Effective Time”). The sale and transfer of the Initial Assets is hereinafter referred to as the “Initial Closing”. 
  

	2.4	Closing of Subsequent Assets 

  
 Subject to satisfaction or waiver of the conditions set forth in Sections 6.1 and 6.2, the sale and transfer of each Subsequent Vendor’s Purchased Assets and payment
of the Subsequent Purchase Price shall take place on a date that is within five (5) Business Days of the Delivery Date for that Subsequent Vendor’s Outstanding Vessel or on such other date as may be agreed upon in writing by that Subsequent
Vendor and the Purchaser (the “Subsequent Closing Time”), with effect as of a time to be agreed by the parties 

  

 9 

 
on such date (the “Subsequent Effective Time”); provided that if any such sale and transfer of a Subsequent Vendor’s Purchased Assets
is scheduled to occur on the Delivery Date, the Time of Closing must be after the registration of the Vessel in the name of the relevant Vendor. 
  
 Each sale and transfer of Subsequent Assets is hereinafter referred to as a “Subsequent Closing”. 
  

	2.5	Place of Closing 

  
 The Initial Closing and each Subsequent Closing shall take place at the offices of Vinson & Elkins L.L.P., 666 Fifth Avenue, New York, New York or such other place as may be agreed upon in writing by the
applicable Vendor and the Purchaser. 
  

	2.6	Assignment and Transfer Documents 

  

	 	(a)	Subject to the terms and conditions hereof, each Vendor will execute and deliver to the Purchaser at or before the applicable Time of Closing of such Vendor’s Purchased Assets,
such deeds of conveyance, bills of sale, assignment documents and all other documents as are necessary to validly complete the sale and transfer to the Purchaser of that Vendor’s Purchased Assets free and clear of all Encumbrances, other than
Permitted Encumbrances, in form and content reasonably acceptable to the Purchaser and that Vendor. 

  

	 	(b)	Without limiting the generality of (a) above, the purchase of each Vessel pursuant to this Agreement shall be concluded on the basis of the Norwegian Shipbrokers’
Association’s memorandum of agreement for the sale and purchase of ships as adopted by BIMCO in “SALEFORM 1993,” in the form attached as Schedule 2.6 logically amended as appropriate in compliance with this Agreement and including the
following other terms (such agreement, the “Vessel Sale Agreement”): 

  

	 	(1)	no deposit shall be paid; 

  

	 	(2)	the Purchaser shall have the right to review the Vessel’s records and classification surveys and inspect the Vessel prior to delivery; 

  

	 	(3)	no drydocking or inspection of underwater parts will be made; 

  

	 	(4)	all items such as bunkers, gas and oil which prior to the applicable Time of Closing, as the case may be, were the property of a charterer, shall remain the property of the
charterer; 

  

	 	(5)	all Excluded Assets are or will be the property of the Manager, pursuant to a sale between the Vendor and the Manager; 

  

	 	(6)	the Vessel Sale Agreement may be cancelled by either party if this Agreement is terminated for any reason; and 

  

	 	(7)	the Vessel Sale Agreement shall be terminated if the Ship Building Contract related to the Outstanding Vessel being purchased and sold thereunder is terminated or cancelled for any
reason whatsoever. 

  

 10 

 If there is any inconsistency between the provisions of this Agreement and any Vessel Sale Agreement, the provisions of
this Agreement will govern. 
  

	2.7	Assumption of Time Charters 

  
 Subject to the provisions of this Agreement, the Purchaser will enter into, with effect after the Time of Closing, an assignment and assumption agreement in the
applicable form attached as Schedule 2.7 with each Vendor in respect of that Vendor’s Time Charter, under which the Purchaser will assume all liabilities and receive all benefits and rights under the Time Charter accruing after the Time of
Closing. 
  

	2.8	Excluded Liabilities 

  
 The Purchaser shall not assume and shall have no obligation to discharge, perform or fulfill any other liabilities or obligations of any Vendor or claims against any Vendor related to any Vendor’s Purchased
Assets of any kind whatsoever in respect of the period of time prior to the Time of Closing of, with respect to any particular Vendor, the purchase and sale of that Vendor’s Purchased Assets, including, but not limited to, with respect to each
Vendor: 
  

	 	(a)	any such liabilities or obligations of that Vendor incurred or accruing due prior to the Time of Closing of that Vendor’s Purchased Assets, including but not limited to, any
claim by a third party arising out of or in connection with the operation of the business of the Vendor or any operating expenses of Vessels on or before the Time of Closing, other than, in the case of an Initial Vendor, the delivery of the services
under that Vendor’s Time Charter in respect of which that Vendor has received a Charter Prepayment, the amount of which has been deducted from the Initial Purchase Price; 

  

	 	(b)	all Taxes of or relating to that Vendor or, with respect to any period of time prior to the Time of Closing of that Vendor’s Purchased Assets, that Vendor’s Purchased
Assets; 

  

	 	(c)	all such liabilities in respect of indebtedness of that Vendor to all persons; 

  

	 	(d)	all such claims and liabilities relating to that Vendor’s Time Charter or other services provided by that Vendor prior to the Time of Closing of that Vendor’s Purchased
Assets; 

  

	 	(e)	any such claims, obligations and liabilities relating to or arising out of the employment of all crew and sea-going employees employed by the Vendor or a sub-contracted party on any
of its Vessels, including liabilities secured by the liens described in paragraph (iii) of the definition of Permitted Encumbrances; 

  

	 	(f)	all liabilities which are secured by or relate to any Permitted Encumbrances existing or relating to a period of time prior to the Time of Closing of that Vendor’s Purchased
Assets, other than such liabilities that relate to those Vessels previously transferred to the Purchaser and incurred after the relevant Time of Closing of those transferred Vessels; 

  

	 	(g)	any such obligations or liabilities of that Vendor related to any breach or default of any kind by that Vendor existing or relating to a period of time prior to the Time of Closing
of that Vendor’s Purchased Assets or arising as a consequence of the transactions contemplated by this Agreement; and 

  

 11 

	 	(h)	subject to Section 7.2, any liabilities or obligations of any Vendor under any Ship Building Contract. 

  
 Each Vendor shall indemnify and save harmless the Purchaser from and against all such liabilities, debts, obligations and claims in
accordance with Section 8.5. 
  

	3.	PURCHASE PRICE 

  

	3.1	Initial Purchase Price 

  
 The aggregate purchase price for the Initial Assets (the “Initial Purchase Price”) is equal to: 
  

	 	(a)	the proceeds (less the underwriting discount and structuring fee) from the sale of 28,570,000 Common Shares in the Initial Public Offering, plus 

  

	 	(b)	the proceeds from the sale of 7,145,000 Subordinated Shares concurrent with the Initial Public Offering, less 

  

	 	(c)	a cash balance of $33.8 million to be retained and used by the Purchaser to pay dividends after the Initial Public Offering and to fund part of the Subsequent Purchase Price, less

  

	 	(d)	$7.5 million in upfront costs, fees and expenses related to the Credit Facility, less 

  

	 	(e)	fees, costs and expenses of approximately $6 million related to the formation of the Purchaser and the Initial Public Offering, less 

  

	 	(f)	$500,000 to repay loans from SCLL in respect of certain offering expenses; less 

  

	 	(g)	the amount that is allocated to any Initial Vendor, pursuant to Section 3.2, whose Vessel Sale Agreement is terminated prior to the Initial Time of Closing.

  

	3.2	Allocation of Initial Purchase Price 

  
 The Initial Vendors and the Purchaser agree to allocate the Initial Purchase Price among the Initial Vendors and among the Initial Assets in accordance with Schedule 3.2
hereto. Each Party will report the sale and purchase of the Initial Assets for all federal, provincial, state and local tax purposes in the form and in a manner consistent with such allocation. Each Party will promptly notify the other if it
receives notice that a taxing authority proposes any allocation that is different from the allocation in Schedule 3.2 hereto. 
  

	3.3	Payment of Initial Purchase Price 

  
 The Initial Purchase Price will be paid by the Purchaser to the Initial Vendors at the Initial Time of Closing by negotiable certified cheque, solicitors trust cheque or
by wire transfer of immediately available funds to an account designated in writing by each Initial Vendor, in respect of the amount of the Initial Purchase Price allocated to that Initial Vendor in Schedule 3.2 hereto. 
  

 12 

	3.4	Subsequent Purchase Price 

  
 The Purchaser shall pay each Subsequent Vendor at the applicable Subsequent Time of Closing the amount set out on Schedule 3.4 across from that Subsequent Vendor’s
name, for that Subsequent Vendor’s Purchased Assets (each, the “Subsequent Purchase Price”). 
  

	3.5	Allocation of Subsequent Purchase Price 

  
 Each Subsequent Vendor and the Purchaser agree to allocate the Subsequent Purchase Price among that Subsequent Vendor’s Purchased Assets in accordance with Schedule
3.4 hereof. Each Party will report the sale and purchase of those Subsequent Assets for all federal, provincial, state and local tax purposes in the form and in a manner consistent with such allocation. Each Party will promptly notify the other if
it receives notice that a taxing authority proposes any allocation that is different from the allocation in Schedule 3.4 hereto. 
  

	3.6	Payment of the Subsequent Purchase Price 

  
 Each Subsequent Purchase Price will be paid by the Purchaser to the Subsequent Vendor of the Subsequent Assets in respect of which that Subsequent Purchase Price is
payable by negotiable certified cheque, solicitors trust cheque or by wire transfer of immediately available funds to an account designated in writing by that Subsequent Vendor. The Subsequent Vendor shall give the Purchaser written notice prior to
the expected Subsequent Closing Time, consistent with the related notice requirements in Article VII, Paragraph 7 of the relevant Ship Building Contract. 
  
 Notwithstanding the foregoing and subject to the conditions below, with regard to the Subsequent Purchase Price in respect of the final four Vessels, the Purchaser may,
with 30 days prior written notice to the relevant Vendor, elect to issue Common Shares to the relevant Vendor in payment of a portion of the Subsequent Purchase Price provided that (a) the maximum amount of the Subsequent Purchase Price for any
Vessel that may be satisfied by the issuance of Common Shares may not exceed the amount set forth opposite the name of the relevant Vessel in the table below; (b) the maximum aggregate amount of the Subsequent Purchase Price for all four such
Vessels that may be satisfied by the issuance of Common Shares may not exceed $100 million; and (c) no Change of Control of the Purchaser has occurred since the Initial Public Offering. In each case, the Common Shares shall be valued at 95% of the
Initial Public Offering price of the Common Shares. 
  

				
	TMM Nuevo Leon	  	$	15 million
	Containership Cassia	  	$	15 million
	CSCL Zeebrugge	  	$	50 million
	CSCL Long Beach	  	$	50 million

  
 In the event that the Purchaser elects
to exercise this option, it shall be a condition that the Purchaser make customary representations and warranties and provide customary legal opinions as to the due authorization and valid issuance of such Common Shares free of any encumbrances. The
Purchaser shall issue such Common Shares in the name of the Vendor or its designee. The option of the Purchaser contained in this Section 3.6 will terminate on a Change of Control of the Purchaser. 
  

 13 

 Each respective Subsequent Vendor will accept such Common Shares as part of the purchase price for such Vessel in
accordance with this Section 3.6 unless a Default exists at the Time of Closing of the respective Vessel. 
  
 If a Default has occurred and is continuing at the Time of Closing, the respective Subsequent Vendor may determine in its sole discretion whether to accept such Common Shares as part of the purchase price for such
Vessel. If a Subsequent Vendor determines not to accept the Common Shares and the Purchaser does not elect to satisfy the entire purchase price in cash, the Purchaser shall be under no obligation to purchase the vessel and shall be released from all
liabilities to the Subsequent Vendor with respect to the purchase and sale of such Vessel, except that, in the case of a Default, the Purchaser shall pay the reasonable out-of-pocket expenses of the Subsequent Vendor resulting directly from or
related to the Purchaser’s election not to purchase the Vessel up to a maximum aggregate amount of $1 million for all Vessels. The Subsequent Vendor shall either sell the Vessel to a third party within 90 days or keep the Vessel and related
Time Charter, subject to the terms of the Omnibus Agreement. 
  

	3.7	Closing Date Purchase Price Adjustments 

  
 To the extent not accounted for in the determination of the Initial Purchase Price payable at the Initial Closing or Subsequent Purchase Price payable at a Subsequent
Closing, as the case may be, the relevant Vendor and the Purchaser will adjust Initial Purchase Price or Subsequent Purchase Price, as the case may be, at the Initial Closing Time or applicable Subsequent Closing Time, as the case may be, for:

  

	 	(a)	in the case of a Subsequent Vendor, any and all adjustments to the Ship Building Contract price paid by the respective Subsequent Vendor to the Builder for the Outstanding Vessel,
including any adjustments pursuant to Article III of the Ship Building Contract but excluding any rebates, discounts or reductions payable to the Vendor pursuant to Section 3.9; 

  

	 	(b)	the amount of any Charter Prepayments, which shall decrease the relevant Initial Purchase Price by such amount; 

  

	 	(c)	all prepaid expenses relating to any of the Purchased Assets, the related liabilities for which the Purchaser would otherwise be responsible under this Agreement or the Management
Agreement after the respective Time of Closing (which excludes, for greater certainty, any expenses or liabilities encompassed in the scope of the Technical Services under the Management Agreement (as defined therein)), which shall increase the
Initial Purchase Price or Subsequent Purchase Price by such amount; and 

  

	 	(d)	all other matters customarily the subject of adjustment; 

  
 and no later than 90 days after the applicable Closing Date will make settlement for the same by certified cheque, wire transfer or bank draft. If the relevant Vendor and
the Purchaser cannot agree to such adjustments, they will refer the matter to dispute resolution and arbitration pursuant to Section 10.9. 
  

 14 

	3.8	Shipyard Deficient Vessel 

  
 In the event that there is a deficiency in an Outstanding Vessel such that the Outstanding Vessel that does not meet the specifications set forth in the relevant Ship
Building Contract then: 
  

	 	(a)	if the relevant Subsequent Vendor is not obligated under the Ship Building Contract to purchase the Vessel or if the relevant Subsequent Vendor is obligated under the Ship Building
Contract to purchase the Vessel but the charterer under the relevant Time Charter refuses to accept the Vessel or refuses to accept the Vessel without any amendments to the relevant Time Charter and the Vendor does not secure prior to the Closing
Date in respect of such Vessel a replacement time charter similar in all material respects to the Time Charter, in the opinion of the Purchaser, acting reasonably: 

  

	 	(1)	the Purchaser may elect to purchase the Vessel from the Subsequent Vendor (in which case the Subsequent Vendor will complete the purchase and sale in accordance with the Ship
Building Contract and the Purchaser will complete the purchase and sale hereunder), and the Purchaser will receive all rebates, discounts or other reductions that result from such deficiency under the respective Ship Building Contract, if any,
including any rebates or adjustments pursuant to Article III of such contract; and 

  

	 	(2)	if the Purchaser elects not to purchase the Vessel, the respective Subsequent Vendor may purchase the Vessel and receive all rebates, discounts or other reductions that result from
such deficiency under the respective Ship Building Contract, if any, including any rebates or adjustments pursuant to Article III of such contract provided that if the Subsequent Vendor elects to purchase and subsequently operates the Vessel, such
acquisition, ownership and operation shall be subject to the terms of the Omnibus Agreement; and 

  

	 	(b)	if the relevant Vendor is obligated under the Ship Building Contract to purchase the Vessel and the charterer under the relevant Time Charter accepts the Vessel with no amendments
to the Time Charter as a result of such deficiencies, the Purchaser will complete the purchase and sale of the Vessel hereunder and will receive all rebates, discounts and reductions that result from such deficiency under the respective Ship
Building Contract, including any rebates or adjustments pursuant to Article III of such contract. 

  

	3.9	Rebates Pursuant to Ship Building Contracts 

  
 With respect to any Outstanding Vessel, the Purchaser will have the right to receive an adjustment, in accordance with Section 3.7, for those rebates, discounts and other
reductions related to any deficiencies of the Vessel to which the Vendor is entitled pursuant to the Ship Building Contract, including pursuant to Article III thereof. All rebates, discounts and reductions in respect of that Subsequent Vendor’s
Ship Building Contract that are unrelated to any deficiency of the Vessel and were negotiated prior to the date of this Agreement will be for the benefit of and payable to the relevant Subsequent Vendor. 
  
 To the extent not accounted for in the determination of the Subsequent Purchase Price payable
at a Subsequent Closing, the relevant Vendor and the Purchaser will adjust for rebates, discounts and reductions in accordance with this Section within 90 days of the applicable Subsequent Closing Time and will make settlement for the same by
certified cheque, wire transfer or bank draft. If the relevant Vendor and the Purchaser cannot agree to such adjustments, they will refer the matter to dispute resolution and arbitration pursuant to Section 10.9. 
  

 15 

 To the extent that the Purchaser receives from the Builder any rebate, discount or reduction in respect of a Ship
Building Contract that, pursuant this Section 3.9, is for the benefit of the Vendor, the Purchaser will hold such funds for and on behalf of the relevant Vendor and make the necessary adjustments in accordance with this Section. 
  

	3.10	Risk of Loss 

  
 Risk of loss of each Purchased Asset will pass to the Purchaser at the Initial Effective Time or Subsequent Effective Time, as the case may be, of that Purchased Asset. The Vendor of such Purchased Asset will bear all
risk of loss or damage to, or destruction of, such Purchased Asset until the Initial Effective Time or Subsequent Effective Time, as the case may be. The Purchaser will bear all such risk of loss after the Initial Effective Time or Subsequent
Effective Time, as the case may be, of that Purchased Asset. 
  

	3.11	Total Loss 

  
 In the event of a Total Loss of a Delivered Vessel, Section 5(d) of the Vessel Sale Agreement with respect to that Vessel will apply and the Purchaser will be released from all obligations with respect to that Vessel
hereunder. 
  

	3.12	Transfer Taxes 

  
 Each Vendor shall be liable for and shall pay for all transfer taxes payable directly or indirectly in connection with this Agreement, including, without limitation, any excise, customs, use, registration, recording,
duties, fees and costs and any other imposts and assessments (exclusive of income taxes) exigible in respect of the transactions contemplated by this Agreement. In the event that the Purchaser, after the Closing Date of the relevant Purchased
Assets, is required to pay or remit any such transfer taxes, duties, costs or other imposts or assessments not paid by the relevant Vendor in accordance with this Section, the relevant Vendor shall indemnify and save the Purchaser harmless in
respect of the same. 
  

	3.13	Letter of Credit 

  
 If, after the Initial Public Offering, a Change of Control of the Purchaser occurs, the Purchaser will provide within 14 days of the Change of Control, and in any event prior to a Time of Closing, a letter of credit,
in favour of the Subsequent Vendors whose Vessels remain outstanding as of such time, from a financial institution that is, and in form and substance, reasonably satisfactory to the Vendors to secure payment of the aggregate Subsequent Purchase
Price for all Outstanding Vessels. The letter of credit will be in an amount equal to the aggregate of the Subsequent Purchase Price for all Outstanding Vessels that have not yet been acquired by the Purchaser in accordance with this Agreement.
After any such Vessel is acquired by the Purchaser in accordance with this Agreement, the Purchaser may replace its letter of credit with a letter of credit that otherwise meets the requirements of this Section. 
  

 16 

	4.	REPRESENTATIONS AND WARRANTIES 

  

	4.1	Representations and Warranties of the Vendors 

  
 Except as set out expressly in this Agreement, the Vendors make no representation or warranty with respect to the Purchased Assets. Each Vendor represents and warrants
that: 
  

	 	(a)	it is a corporation duly incorporated, organized and validly existing in good standing under the laws of the Republic of Cyprus and has full power and capacity to enter into, carry
out the transactions contemplated by and duly observe and perform all its obligations contained in this Agreement; 

  

	 	(b)	the execution and delivery of this Agreement and all documents, instruments and agreements required to be executed and delivered by it pursuant to this Agreement, and the completion
of the transactions contemplated by this Agreement, have been duly authorized by all necessary action on its part, and this Agreement has been duly executed and delivered by it and constitutes a legal, valid and binding obligation of it enforceable
in accordance with its terms, except as may be limited by bankruptcy, insolvency, liquidation, reorganization, reconstruction and other similar laws of general application affecting the enforceability of remedies and rights of creditors and except
that equitable remedies such as specific performance and injunction are in the discretion of a court; 

  

	 	(c)	the execution, delivery and performance by it of this Agreement will not conflict with or result in any violation of or constitute a breach of any of the terms or provisions of, or
result in the acceleration of any obligation under, or constitute a default under any provision of: (i) its articles of incorporation or bylaws or other organizational documents, including any resolution of its board of directors (or any committee
thereof); (ii) any Encumbrance, bond, indenture, agreement, contract, franchise licence, permit or other instrument or obligation to which it is a party or is subject or by which any of its assets or properties may be bound; (iii) any Applicable
Law; and (iv) its Time Charter or Ship Building Contract or any material provision of any material contract to which it is party or by which its properties are bound other than the Existing Credit Facilities and Existing Credit Facilities Security;

  

	 	(d)	except as set forth in Schedule 4.1(d) and except as have already been obtained, no consent, permit, approval or authorization of, notice or declaration to or filing with any
Governmental Authority or any other Person, including those related to any environmental laws or regulations, is required in connection with the execution and delivery by it of this Agreement or the consummation by it of the transactions
contemplated hereunder and any consents required for the transfer or assignment of the Time Charters pursuant to Sections 2.1(b) and 2.2(b) of this Agreement have been duly obtained; 

  

	 	(e)	its Purchased Assets are owned beneficially by it with a good and marketable title thereto, free and clear of all Encumbrances other than Permitted Encumbrances and the Existing
Credit Facilities Security; 

  

	 	(f)	there is no agreement, contract, option, commitment or other right or understanding in favour of, or held by, any Person other than the Purchaser to acquire any of its Purchased
Assets that has not been waived; 

  

	 	(g)	correct and complete copies of its constating documents (as amended to the date hereof), Time Charter and its Ship Building Contract have been made available to the Purchaser;

  

 17 

	 	(h)	its Time Charter and Ship Building Contract are in good standing and in full force and effect and, except as specifically set out in Schedules 1C and 1.1, unamended;

  

	 	(i)	to the best of its knowledge, its Time Charter and Ship Building Contract are valid and binding obligations of the other parties thereto enforceable in accordance with their
respective terms; 

  

	 	(j)	it has complied with all material terms of its Time Charter and Ship Building Contract, has paid all material amounts due thereunder, has not waived any material rights thereunder
and no material default or breach exists in respect thereof on its part or, to its knowledge, any of the other parties thereto and, to its knowledge, no event has occurred which, after the giving of notice or the lapse of time or both, would
constitute such a material default or breach; 

  

	 	(k)	if it is an Initial Vendor, its Delivered Vessel is, or if it is a Subsequent Vendor, its Outstanding Vessel will be at the respective Time of Closing: (i) free and clear of all
Encumbrances, other than Permitted Encumbrances and the Existing Credit Facilities Security, which will be discharged at the relevant Time of Closing in accordance with Section 6.1(k), and good and marketable title thereto will be transferred to the
Purchaser at the Time of Closing; (ii) adequate and suitable for use by the Vendor in its business as presently conducted by it in all material respects, ordinary wear and tear excepted; (iii) seaworthy in all material respects for hull and
machinery insurance warranty purposes and is in good running order and repair; (iv) insured against all risks, and in amounts, consistent with common industry practices; (v) in compliance with maritime laws and the ISM Code; (vi) duly registered
under the flag set forth opposite the Delivered Vessel’s name on Schedule 1A hereto; (vii) in compliance in all material respects with the requirements of its present class and classification society; and all class certificates of the Delivered
Vessel are clean and valid and free of recommendations affecting class; and the Purchaser acknowledges and agrees that, subject only to the representations and warranties in this subsection, it is acquiring the Vessel on an “as is, where
is” basis; 

  

	 	(l)	except as disclosed in the Financial Statements, and except as incurred in the ordinary course of business since the date of the Financial Statements, there is no material
liability, debt or obligation of or claim against it relating to any of its Purchased Assets that is known or should reasonably be known to it; 

  

	 	(m)	except as set forth on Schedule 4.1(m), there are no actions, suits or proceedings pending or, to its knowledge, threatened at law or in equity, before or by any Governmental
Authority or before any arbitrator of any kind, against it (other than any such actions, suits or proceedings that could not reasonably be expected to adversely impact its ability to consummate the transactions contemplated hereby or to adversely
impact the value of the Purchased Assets) and it is not subject to any settlements, consent decrees, judgments, injunctions, orders or findings related to the Purchased Assets that would reasonably be expected to adversely impact its ability to
consummate the transactions contemplated hereby or to adversely impact the value of the Purchase Assets; and 

  

 18 

	 	(n)	it owns or possesses all material licences, permits, franchises, registrations and similar authorizations of any Government Authority which are necessary and used in the operation
of its business as of the date hereof (each, a “Licence” and collectively, the “Licences”); except as set out in Schedule 4.1(n) no such Licence will terminate or be subject to termination or revocation as a result
of the consummation of the transactions contemplated hereby; all Licences are in full force and effect and no proceeding is pending or, to the knowledge of the Vendor, threatened seeking the revocation or limitation of any such Licence; and all
required filings with respect to Licenses have been timely made and all required applications for renewal thereof have been timely filed. 

  

	4.2	Representations and Warranties of the Purchaser 

  
 The Purchaser represents and warrants that: 
  

	 	(a)	it is a corporation duly incorporated, organized and validly existing under the laws of the Marshall Islands; and has full power and capacity to enter into, carry out the
transactions contemplated by, and duly observe and perform all its obligations contained in this Agreement; 

  

	 	(b)	the execution and delivery of this Agreement and all documents, instruments and agreements required to be executed and delivered by it pursuant to this Agreement, and the completion
of the transactions contemplated by this Agreement, have been duly authorized by all necessary corporate action on its part, and this Agreement has been duly executed and delivered by it and constitutes a legal, valid and binding obligation of it
enforceable in accordance with its terms, except as may be limited by bankruptcy, insolvency, liquidation, reorganization, reconstruction and other similar laws of general application affecting the enforceability of remedies and rights of creditors
and except that equitable remedies such as specific performance and injunction are in the discretion of a court; 

  

	 	(c)	neither the execution and delivery of this Agreement nor the completion and performance of the transactions and obligations contemplated by or contained in this Agreement will
result in a breach of or default under, or be contrary to, any of the provisions of its articles of incorporation or bylaws or other organizational documents including any resolution if its board of directors (or any committee thereof) or any
Encumbrance, indenture, contract, agreement or instrument to which it is a party or by which it is bound; and 

  

	 	(d)	subject to the provisions of Section 3.6 above, at each respective Closing Date, the Purchaser will have sufficient available funds to pay the purchase price for each Vessel.

  

	4.3	Representations and Warranties of SCLL 

  
 SCLL represents and warrants that: 
  

	 	(a)	it legally and beneficially owns all of the issued and outstanding shares of each of the Vendors; 

  

 19 

	 	(b)	it is a corporation duly incorporated, organized and validly existing in good standing under the laws of the Republic of Cyprus and has full power and capacity to enter into, carry
out the transactions contemplated by and duly observe and perform all its obligations contained in this Agreement; 

  

	 	(c)	the execution and delivery of this Agreement and all documents, instruments and agreements required to be executed and delivered by it pursuant to this Agreement, and the completion
of the transactions contemplated by this Agreement, have been duly authorized by all necessary action on its part, and this Agreement has been duly executed and delivered by it and constitutes legal, valid and binding obligations of it enforceable
in accordance with its terms, except as may be limited by bankruptcy, insolvency, liquidation, reorganization, reconstruction and other similar laws of general application affecting the enforceability of remedies and rights of creditors and except
that equitable remedies such as specific performance and injunction are in the discretion of a court; and 

  

	 	(d)	the execution, delivery and performance by it of this Agreement will not conflict with or result in any violation of or constitute a breach of any of the terms or provisions of, or
result in the acceleration of any obligation under, or constitute a default under any provision of: (i) its articles of incorporation or bylaws or other organizational documents, including any resolution of its board of directors (or any committee
thereof); (ii) any Encumbrance, bond, indenture, agreement, contract, franchise licence, permit or other instrument or obligation to which it is a party or are subject or by which any of its assets or properties may be bound; (iii) any Applicable
Law; and (iv) any material provision of any material contract to which it is a party or by which its properties are bound. 

  

	5.	PRE-CLOSING MATTERS 

  

	5.1	Covenants of the Vendors Prior to Closing 

  
 Each Vendor hereby agrees and covenants that during the period of time after the date of this Agreement and prior to the Time of Closing of that Vendor’s Purchased
Assets, that Vendor: 
  

	 	(a)	shall continue to maintain in full force and effect all policies of insurance and renewals thereof now in effect in respect of that Vendor’s Purchased Assets;

  

	 	(b)	shall cooperate with the Purchaser and use its reasonable best efforts to obtain, at or prior to the Time of Closing of that Vendor’s Purchased Assets, the consents required in
respect of the assignment or transfer of that Vendor’s Vessel Warranties and all other rights and benefits under the Ship Building Contract, to the extent assignable; 

  

	 	(c)	shall use its reasonable best efforts to take or cause to be taken promptly all actions and to do or cause to be done all things necessary, proper and advisable to consummate and
make effective as promptly as practicable the transactions contemplated by this Agreement and to cooperate with the Purchaser in connection with the foregoing, including using all reasonable best efforts to obtain all necessary consents, approvals
and authorizations from each Governmental Authority and each other Person that are required to consummate the transactions contemplated under this Agreement; 

  

 20 

	 	(d)	shall take or cause to be taken all necessary corporate action, steps and proceedings to approve or authorize validly and effectively the purchase and sale of that Vendor’s
Purchased Assets and the execution and delivery of this Agreement and the other agreements and documents contemplated hereby; 

  

	 	(e)	shall use reasonable best efforts to preserve and protect that Vendor’s Purchased Assets; 

  

	 	(f)	shall comply in all material respects with all Applicable Laws affecting the operation of that Vendor’s Purchased Assets; 

  

	 	(g)	shall pay all Taxes due and payable relating to the operation of its Purchased Assets which arise prior to, or are related to, a period of time prior to the Time of Closing of its
Purchased Assets; 

  

	 	(h)	shall not cause or, to the extent reasonably within its control, sell, transfer or dispose of any of that Vendor’s Purchased Assets; 

  

	 	(i)	shall not amend, alter or otherwise modify any material provision of or terminate its respective Time Charter or Ship Building Contract without the prior written consent of the
Purchaser, not to be unreasonably withheld or delayed; and 

  

	 	(j)	shall not cause or, to the extent reasonably within its control, permit any Encumbrance to attach to or affect any of that Vendor’s Purchased Assets, other than Permitted
Encumbrances and the Existing Credit Facilities Security. 

  

	5.2	Covenants of the Purchaser Prior to Closing 

  
 The Purchaser hereby agrees and covenants that during the period of time after the date of the Agreement and prior to each Time of Closing, the Purchaser shall, in
respect of the Purchased Assets to be transferred at each such Time of Closing, take, or cause to be taken, all necessary corporate action, steps and proceedings to approve or authorize validly and effectively the purchase and sale of those
Purchased Assets and the execution and delivery of this Agreement and the other agreements and documents contemplated hereof. 
  

	5.3	Provisions in Respect of Time Charters and Ship Building Contracts 

  
 Each Vendor and the Purchaser covenants and agrees that from the date of this Agreement until the Time of Closing of a Vendor’s Purchased Assets: 
  

	 	(a)	each Vendor shall not exercise any rights under or options contained in that Vendor’s Time Charter, Ship Building Contract or Vessel Warranties, without the prior approval of
the Purchaser, not to be unreasonably withheld or delayed; 

  

	 	(b)	 with respect to the Outstanding Vessels, each Vendor shall consult with the Purchaser regarding (i) all material decisions to be made pursuant to the Ship Building
Contracts, and shall make such decisions only with the prior approval of the Purchaser, not to be unreasonably withheld or delayed; (ii) any other matter material to the condition or operation of such Outstanding Vessel, and shall make any decisions
arising therefrom 

  

 21 

	 	 
only with the prior approval of the Purchaser, not to be unreasonably withheld or delayed; and (iii) any inspections of the Outstanding Vessels;

  

	 	(c)	each Vendor shall observe and perform in a timely manner, all of its covenants and obligations under its Time Charter and Ship Building Contract, if any, and (i) in the case of a
default by another party thereto, it shall forthwith advise the Purchaser of such default and shall, if requested by the Purchaser, enforce all of its rights under such Time Charter or Ship Building Contract in respect of such default; and (ii)
subject to the rights of the lenders under the Existing Credit Facilities and Existing Credit Facilities Security, in the case of a breach or anticipated breach of either agreement by the Vendor, it shall permit the Purchaser to cure on its behalf
such breach or anticipated breach and shall promptly reimburse the Purchaser for any and all costs that the Purchaser may expend in order to effect such cure; and 

  

	 	(d)	each Vendor will not, from and after the date of this Agreement, negotiate any further rebate, reduction, discount or refund with respect to the purchase price of the Vessel as set
out in the relevant Ship Building Contract, without the prior approval of the Purchaser; and 

  

	 	(e)	if any amendment, alteration or modification of any material provision of a Vendor’s Ship Building Contract approved by the Purchaser pursuant to Section 5.1(i), any exercise
of rights of a Vendor approved by the Purchaser pursuant to Sections 5.3(a) or any options or material decision approved by the Purchaser pursuant to Section 5.3(b) results in: (i) an increase in the purchase price of the Vendor under the relevant
Ship Building Contract, the Subsequent Purchase Price will be increased accordingly pursuant to Section 3.7; or (ii) a decrease in the purchase price of the Vendor under the relevant Ship Building Contract, the Subsequent Purchase Price will be
decreased accordingly pursuant to Section 3.7. 

  

	5.4	Delivery of Vessel Sale Agreement 

  
 As soon as practicable after the execution and delivery of this Agreement, each Vendor shall execute and deliver to the Purchaser, a Vessel Sale Agreement in respect of
that Vendor’s Outstanding Vessel or Delivered Vessel, as the case may be, in form and substance as set out in Schedule 2.6 hereto. 
  

	6.	CONDITIONS OF CLOSING 

  

	6.1	Conditions of the Purchaser 

  
 The obligation of the Purchaser to complete the purchase of any Vendor’s Purchased Assets is subject to the fulfilment of the following conditions: 
  

	 	(a)	the representations and warranties of that Vendor and SCLL contained in this Agreement being true and correct on and as of the Time of Closing of that Vendor’s Purchased Assets
with the same effect as though such representations and warranties had been made as of the Time of Closing of that Vendor’s Purchased Assets; 

  

 22 

	 	(b)	all of the covenants and obligations of that Vendor and SCLL to be performed or observed on or before the Time of Closing of that Vendor’s Purchased Assets pursuant to this
Agreement having been duly performed or observed; 

  

	 	(c)	in respect of the Initial Closing and each Subsequent Closing, each of the relevant Vendors has delivered to the Purchaser a duly executed copy of the documents and agreements
described in Section 2.6(a) with respect to the Delivered Vessels or each Outstanding Vessel, as the case may be; 

  

	 	(d)	there having been delivered to the Purchaser a certificate of that Vendor dated the applicable Closing Date, executed by an authorized officer or director of that Vendor, certifying
that the representations and warranties made by that Vendor in this Agreement are true and correct as at the Time of Closing of that Vendor’s Purchased Assets and that all covenants and obligations to be observed or performed by that Vendor on
or before the Initial Closing or applicable Subsequent Closing, as the case may be, pursuant to the terms of this Agreement have been duly observed and performed; 

  

	 	(e)	the board of directors of the Purchaser will have approved this Agreement and the transactions contemplated by this Agreement; 

  

	 	(f)	the notifications, consents and approvals referred to in item 2 of Schedule 4.1(d) hereto shall have been given or obtained; 

  

	 	(g)	all consents required in respect of the assignment of that Vendor’s Time Charter to the Purchaser shall have been obtained from third parties; 

  

	 	(h)	the Purchaser shall have entered into the Management Agreement, which shall not have been terminated and shall remain effective as of the Time of Closing; 

 

	 	(i)	all proceedings to be taken in connection with the transactions contemplated by this Agreement and all documents incidental thereto shall be reasonably satisfactory in form and
substance to the Purchaser and its counsel, and the Purchaser shall have received copies of all such documents and other evidence as it or its counsel may reasonably request in order to establish the consummation of such transactions and the taking
of all proceedings in connection therewith; 

  

	 	(j)	no legal or regulatory action or proceeding shall be pending or threatened by any Governmental Authority to enjoin, restrict or prohibit the purchase and sale of that Vendor’s
Purchased Assets; 

  

	 	(k)	all advances made under the Existing Credit Facilities have been repaid or will be repaid from the Initial Purchase Price or Subsequent Purchase Price, or from other funds of the
Vendor, as the case may be, such that, the Vendor’s Delivered Vessel or Outstanding Vessel, as the case may be, shall be transferred to the Purchaser free and clear of all Encumbrances other than Permitted Encumbrances and the Permitted
Encumbrances and relevant Existing Credit Facility Security will be discharged reasonably promptly following the relevant Time of Closing; and 

  

 23 

	 	(l)	in the case of the Initial Vessels, the Purchaser has completed an inspection of the Initial Vessels to the Purchaser’s reasonable satisfaction; and in the case of the
Subsequent Vessels, the Purchaser is satisfied that the relevant Subsequent Vendor has inspected the Outstanding Vessel prior to the Delivery Date in accordance with the relevant Ship Building Contract. 

  
 In the event that any of the foregoing conditions is not performed or fulfilled at or before
the Time of Closing of that Vendor’s Purchased Assets, the Purchaser may terminate this Agreement with respect to that Vendor, in which event the Purchaser will be released from all obligations under this Agreement in respect of that Vendor,
including the payment of that portion of the Purchase Price to such Vendor, and that Vendor will also be so released unless such Vendor was reasonably capable of causing such condition or conditions to be fulfilled or unless that Vendor breached any
of its covenants or obligations in or under this Agreement. The foregoing conditions are for the benefit of the Purchaser only and accordingly the Purchaser will be entitled to waive compliance with any such conditions if it sees fit to do so,
without prejudice to its rights and remedies at law and in equity and also without prejudice to any of its rights of termination in the event of non-performance of any other conditions in whole or in part. 
  

	6.2	Conditions of the Vendors 

  
 The obligation of each Vendor to complete the sale of that Vendor’s Purchased Assets contemplated by this Agreement is subject to the fulfilment of each of the
following conditions: 
  

	 	(a)	the representations and warranties of the Purchaser contained in this Agreement being true on and as of the Time of Closing of that Vendor’s Purchased Assets with the same
effect as though such representations and warranties had been made as of the Time of Closing of that Vendor’s Purchased Assets; 

  

	 	(b)	all of the covenants and obligations of the Purchaser to be performed or observed on or before the Time of Closing of that Vendor’s Purchased Assets pursuant to this Agreement
having been duly performed or observed; 

  

	 	(c)	there having been delivered to that Vendor a certificate of the Purchaser dated the applicable Closing Date, executed by an authorized officer or director of the Purchaser,
certifying that the representations and warranties made by the Purchaser in this Agreement are true and correct as at the Time of Closing of that Vendor’s Purchased Assets and that the covenants and obligations to be observed or performed by
the Purchaser on or before the Time of Closing of that Vendor’s Purchased Assets pursuant to the terms of this Agreement have been duly observed and performed; 

  

	 	(d)	no legal or regulatory action or proceeding shall be pending or threatened by any Governmental Authority to enjoin, restrict or prohibit the purchase and sale of that Vendor’s
Purchased Assets; 

  

	 	(e)	in respect of the Initial Closing, the Initial Public Offering has been completed; 

  

	 	(f)	the Purchaser shall have entered into the Management Agreement, which shall not have been terminated and shall remain effective as of the Time of Closing; and

  

 24 

	 	(g)	all proceedings to be taken in connection with the transactions contemplated by this Agreement and all documents incidental thereto shall be reasonably satisfactory in form and
substance to the Vendors and their counsel, and the Vendors shall have received copies of all such documents and other evidence as they or their counsel may reasonably request in order to establish the consummation of such transactions and the
taking of all proceedings in connection therewith. 

  
 In the event
that any of the foregoing conditions are not performed or fulfilled at or before the Time of Closing of that Vendor’s Purchased Assets, the Vendor may terminate this Agreement, in which event, that Vendor will be released from all obligations
under this Agreement, and the Purchaser will also be so released in respect of that Vendor unless the Purchaser was reasonably capable of causing such condition or conditions to be fulfilled or unless the Purchaser has breached any of its covenants
or obligations in or under this Agreement. The foregoing conditions are for the benefit of each Vendor individually, and accordingly each Vendor will be entitled to only waive compliance with any such conditions in respect of itself, if it sees fit
to do so, without prejudice to its rights and remedies at law and in equity and also without prejudice to any of its rights of termination in the event of non-performance of any other conditions in whole or in part. 
  

	6.3	Actions to Satisfy Closing Conditions 

  
 Each Party shall take all actions as are within its power and otherwise use its commercially reasonable efforts so as to ensure compliance with the conditions set forth
in this Section 6. 
  

	7.	POST-CLOSING COVENANTS 

  

	7.1	Exercise Under Ship Building Contracts 

  
 If and to the extent that a Vendor is unable to assign to the Purchaser any of the Vessel Warranties or any of its rights or benefits under its Ship Building Contract in
accordance with this Agreement prior to the applicable Time of Closing or if at any time and from time to time after the applicable Time of Closing, the Purchaser is unable to exercise fully any of its rights, or derive the full benefit of such
rights, under the relevant Ship Building Contract, including with respect to the “Warranty of Quality” described in Article IX in such Ship Building Contract, any extended guarantee rights contained in the Ship Building Contract and any
guarantee by the paint manufacturer with respect to defects in paint and/or application or underwater parts of the Vessel, or of any of the Vendor’s Vessel Warranties or any rights or benefits related thereto, that Vendor shall, at the request
of the Purchaser, enforce all or any of its rights under that Vendor’s Ship Building Contract or the relevant Vessel Warranties, as the case may be, and promptly deliver to the Purchaser any such benefits received thereunder. 
  

	7.2	Post-Delivery Obligations 

  
 The Purchaser will abide by and comply with the Post-Delivery Obligations in connection with the enjoyment or exercise of any right or benefit assigned to the Purchaser
under Sections 2.1(d) and 2.2(d) or derived by the Purchaser under Section 7.1 and will pay for all such expenses and costs charged by the Builder, if any, in association therewith. 
  

 25 

	7.3	Covenants of SCLL 

  
 SCLL covenants and agrees that: 
  

	 	(a)	for so long as any obligation of a Vendor is outstanding under this Agreement: (i) it shall not sell or transfer, whether by one or a series of transactions, any part of the issued
share capital of that Vendor without the prior written consent of the Purchaser; and (ii) it will provide that Vendor with such support and assistance as may be required to enable it to maintain its good standing in Cyprus; 

 

	 	(b)	it will cause each Vendor to perform its obligations under this Agreement in accordance with its terms and, in particular, it will cause each Subsequent Vendor to take delivery of
its Outstanding Vessel under the relevant Ship Building Contract if required to do so in accordance with the terms of the relevant Ship Building Contract and this Agreement; and 

  

	 	(c)	it will cause each Vendor to transfer the relevant Purchased Assets to the Purchaser against the Purchaser’s payment of the Initial Purchase Price or Subsequent Purchase Price,
as the case may be, in accordance with the terms and conditions of this Agreement. 

  

	8.	SURVIVAL OF REPRESENTATIONS AND RECOURSE 

  

	8.1	Survival of Representations, Warranties and Covenants of the Vendors 

  

The representations and warranties of each Vendor in or under this Agreement (other than in respect of Sections 4.1(e) and 4.1(k)(i)), and in or under any documents,
instruments and agreements delivered pursuant to this Agreement, will survive the completion of the transactions contemplated hereby regardless of any independent investigations that the Purchaser may make or cause to be made, or knowledge it may
have, prior to the applicable Time of Closing and will continue in full force and effect for a period of one year from the applicable Closing Date. At the end of such period, such representations and warranties will terminate and no claim may be
brought by the Purchaser against any Vendor thereafter in respect of such representations and warranties, except for claims that have been asserted by the Purchaser prior to such termination. 
  
 The representations and warranties of each Vendor under Sections 4.1(e) and 4.1(k)(i) will
survive the completion of the transactions contemplated hereby, regardless of any independent investigations that the Purchaser may make or cause to be made, or knowledge it may have, prior to the applicable Time of Closing, and will continue in
full force and effect, and will not terminate, indefinitely. 
  
 The covenants and
obligations of each of the Vendors in or under this Agreement (other than in respect of Sections 2.8, 7.1, 8 and 10.2) and in or under any documents, instruments and agreements delivered pursuant to this Agreement, will survive the completion of the
transactions contemplated hereby regardless of any independent investigations that the Purchaser may make or cause to be made, or knowledge it may have, prior to the applicable Time of Closing and will continue in full force and effect for a period
of two years from the applicable Closing Date. At the end of such period, such covenants and obligations will terminate and no claim may be brought by the Purchaser against any Vendor thereafter in respect of such covenants and obligations, except
for claims that have been asserted by the Purchaser 

  

 26 

 
prior to such termination. The covenants and obligations of each of the Vendors in respect of Sections 2.8, 8 and 10.2 will survive indefinitely. 

 
 The covenants and obligations of each of the Vendors in or under Section 7.1 will survive
the completion of the transactions contemplated hereby regardless of any independent investigations that the Purchaser may make or cause to be made, or knowledge it may have, prior to the applicable Time of Closing and will terminate when the
underlying Vessel Warranties, rights or benefits under the relevant Ship Building Contract, as the case may be, have terminated or otherwise expired. At the end of such period, such covenants and obligations will terminate and no claim may be
brought by the Purchaser against the Vendor thereafter in respect of such covenants and obligations, except for claims that have been asserted by the Purchaser prior to such termination. 
  

	8.2	Survival of Representations, Warranties and Covenants of the Purchaser 

  

The representations and warranties of the Purchaser in or under this Agreement and in or under any documents, instruments and agreements delivered pursuant to this
Agreement, will survive the completion of the transactions contemplated hereby regardless of any independent investigations that any Vendor may make or cause to be made, or knowledge either of them may have, prior to the applicable Time of Closing
and will continue in full force and effect for a period of one year from the applicable Closing Date. At the end of such period, such representations and warranties will terminate and no claim may be brought by the relevant Vendor against the
Purchaser thereafter in respect of such representations, and warranties, except for claims that have been asserted by the Vendor prior to such termination. 
  
 The covenants and obligations of the Purchaser in this Agreement (other than in respect of Sections 2.7, 7.2, 8 and 10.2), and in or under any documents, instruments and
agreements delivered pursuant to this Agreement, will survive the completion of the transactions contemplated hereby regardless of any independent investigations that the Vendors may make or cause to be made, or knowledge it may have, prior to the
applicable Time of Closing and will continue in full force and effect for a period of two years from the applicable Closing Date. At the end of such period, such covenants and obligations will terminate and no claim may be brought by the relevant
Vendor against the Purchaser thereafter in respect of such covenants and obligations, except for claims that have been asserted by the Vendors prior to such termination. The covenants and obligations of the Purchaser in respect of Sections 2.7, 8
and 10.2 will survive indefinitely. 
  
 The covenants and obligations of the
Purchaser in or under Section 7.2 of this Agreement will terminate when the underlying Vessel Warranties, rights or benefits under the relevant Ship Building Contract, as the case may be, have terminated or otherwise expired. At the end of such
period, such covenants and obligations will terminate and no claim may be brought by the relevant Vendor against the Purchaser thereafter in respect of such covenants and obligations, except for claims that have been asserted by the Purchaser prior
to such termination. 
  

	8.3	Survival of Representations, Warranties and Covenants of SCLL 

  
 The representations and warranties of SCLL in or under this Agreement, and in or under any documents, instruments and agreements delivered pursuant to this Agreement,
will survive the completion of the transactions contemplated hereby regardless of any independent investigations that the Purchaser may make or cause to be made, or knowledge either of them may have, prior to the applicable Time of Closing 

  

 27 

 
and will continue in full force and effect for a period of one year from the applicable Closing Date. At the end of such period, such representations and
warranties will terminate and no claim may be brought by the Purchaser against SCLL thereafter in respect of such representations and warranties, except for claims that have been asserted by the Purchaser prior to such termination. 
  
 The covenants and obligations of SCLL in or under this Agreement, and in or under any
documents, instruments and agreements delivered pursuant to this Agreement, will survive the completion of the transactions contemplated hereby regardless of any independent investigations that the Purchaser may make or cause to be made, or
knowledge it may have, prior to the applicable Time of Closing and will continue in full force and effect for so long as any Vendor has any obligation outstanding under this Agreement. At the end of such period, such covenants and obligations will
terminate and no claim may be brought by the Purchaser against SCLL thereafter in respect of such covenants and obligations, except for claims that have been asserted by the Purchaser prior to such termination. 
  

	8.4	Reliance 

  
 Each Vendor acknowledges and agrees that the Purchaser is relying on the representations and warranties and other terms and conditions of this Agreement notwithstanding any independent searches or investigations that
may be undertaken by or on behalf of the Purchaser and that no information which is now known or should be known or which may hereafter become known to the Purchaser, its Affiliates, employees, representatives or agents, will limit or extinguish the
rights of the Purchaser with respect to any misrepresentation or breach of any warranty, covenant or obligation by such Vendor. 
  

	8.5	Indemnity by the Vendors 

  
 Each Vendor will indemnify, defend and hold harmless the Purchaser and the respective current and former directors, officers and employees of the Purchaser and its
Affiliates and their heirs, successors and assigns (the “Purchaser’s Indemnified Persons”) harmless from and against all Losses suffered or incurred by the Purchaser’s Indemnified Persons: 
  

	 	(a)	by reason of, arising out of or otherwise in respect of any inaccuracy in, breach of any representation or warranty, or a failure to perform or observe fully any covenant, agreement
or obligation of, that Vendor in or under this Agreement or in or under any document, instrument or agreement delivered pursuant to this Agreement by such Vendor; 

  

	 	(b)	arising out of or in connection with any liabilities or obligations of that Vendor relating to that Vendor’s Purchased Assets or otherwise encompassed in Section 2.8 of this
Agreement; 

  

	 	(c)	arising out of or in connection with any and all claims of third parties relating to that Vendor’s Purchased Assets or the operation thereof at or before the respective Time of
Closing; or 

  

	 	(d)	arising out of or in connection with any tax liabilities of that Vendor relating to the Vendor’s Purchased Assets, including any assessment or re-assessment by a taxing
authority of any tax return of that Vendor. 

  

 28 

 Any claim for indemnification made pursuant to Section 8.5(a) in respect of representations and warranties must be made
within one year from the applicable Closing Date. Any claim for indemnification made pursuant to Section 8.5(a) in respect of covenants and obligations (other than covenants and obligations under Sections 2.8, 7.1, 8 and 10.2) must be made within
two years from the applicable Closing Date. Any claim for indemnification in respect of covenants and obligations under Section 7.1 must be made within the time specified in Section 8.1. Any claim for indemnification made pursuant to Section 8.5(d)
must be made within ten years from the applicable Closing Date. All other claims for indemnification pursuant to Section 8.5 may be made at any time. 
  

	8.6	Indemnity by the Purchaser 

  
 The Purchaser will indemnify and save each Vendor and its current and former directors, officers and employees of each Vendor and its Affiliates and their heirs,
successors and assigns (the “Vendors’ Indemnified Persons”) harmless from and against all Losses suffered or incurred by the Vendors’ Indemnified Persons: 
  

	 	(a)	by reason of, arising out of or otherwise in respect of any inaccuracy in, breach of any representation or warranty, or a failure to perform or observe fully any covenant, agreement
or obligation of, the Purchaser in or under this Agreement or in or under any document, instrument or agreement delivered pursuant to this Agreement by the Purchaser; 

  

	 	(b)	arising out of or in connection with any liabilities or obligations of that Vendor relating to that Vendor’s Purchased Assets assumed by the Purchaser pursuant to Section 2.7
of this Agreement; or 

  

	 	(c)	arising out of or in connection with any and all claims of third parties relating to that Vendor’s Purchased Assets or the operation thereof, in each case after the respective
Time of Closing, provided that such claim or the event giving rise thereto did not arise prior to the relevant Time of Closing. 

  
 Any claim for indemnification made pursuant to Section 8.6(a) in respect of representations and warranties must be made within one year from the applicable Closing Date.
Any claim for indemnification made pursuant to Section 8.6(a) (other than covenants and obligations under Sections 2.7, 7.2, 8 and 10.2) must be made within two years from the applicable Closing Date. Any claim for indemnification in respect of
covenants and obligations under Section 7.2 must be made within the time specified in Section 8.2. All other claims for indemnification pursuant to Section 8.6 may be made at any time. 
  

	8.7	Indemnity by SCLL 

  
 SCLL will indemnify and save the Purchaser’s Indemnified Persons harmless from and against all Losses suffered or incurred by the Purchaser’s Indemnified Persons 
  

	 	(a)	by reason of, arising out of or otherwise in respect of any inaccuracy in, breach of any representation or warranty, or a failure to perform or observe fully any covenant, agreement
or obligation, of SCLL in or under this Agreement or in or under any document, instrument or agreement delivered pursuant to this Agreement by SCLL; or 

  

 29 

	 	(b)	arising out of or in connection with any tax liabilities or obligations of SCLL relating to the Vendors or any of the Vendors’ Purchased Assets, including any assessment or
re-assessment by a taxing authority of any tax return of SCLL. The obligations of SCLL under this subsection and the Vendors under Section 8.5(d) are joint and several. 

  
 Any claim for indemnification made pursuant to Section 8.7(a) must be made within the time
period stated in Section 8.3. Any claim for indemnification made pursuant to Section 8.7(b) must be made within ten years from the applicable Closing Date. 
  

	8.8	Defence of Third Party Claims 

  
 If a claim (an “Indemnity Claim”) is made by a third party against a Party (the “Indemnified Party”) in respect of which another Party
(the “Indemnifier”) is or may be obligated under or arising out of this Agreement to indemnify, pay damages to or otherwise compensate the Indemnified Party, including claims made pursuant to Sections 8.5 and 8.6 above, then the
following provisions will apply. 
  

	 	(a)	If any Indemnified Party receives notice of the assertion of any claim in respect of damages, such Indemnified Party shall give the Indemnifier written notice describing such claim
or fact in reasonable detail (the “Notice of Claim”) promptly (and in any event within ten (10) Business Days after receiving any written notice from a third party). The failure by the Indemnified Party to timely provide a Notice of
Claim to the Indemnifier shall not relieve the Indemnifier of any liability, except to the extent that the Indemnifier is prejudiced by the Indemnified Party’s failure to provide timely notice hereunder. 

  

	 	(b)	In the event any Indemnifier notifies the Indemnified Party within ten (10) Business Days after the Indemnified Party has given notice of the matter that the Indemnifier is assuming
the defence thereof; (i) the Indemnifier will defend the Indemnified Party against the matter with counsel of its choice reasonably satisfactory to the Indemnified Party; (ii) the Indemnified Party may retain separate co-counsel at its sole cost and
expense (except that the Indemnifier will be responsible for the fees and expenses of the separate co-counsel to the extent the Indemnified Party reasonably concludes that the counsel the Indemnifier has selected has a conflict of interest); (iii)
the Indemnified Party will not consent to the entry of any judgment or enter into any settlement with respect to the matter without written consent of the Indemnifier which consent shall not be unreasonably withheld; and (iv) the Indemnifier will
not consent to the entry of any judgment with respect to the matter, or enter into any settlement which does not include a provision whereby the plaintiff or claimant in the matter releases the Indemnified Party from all liability with respect
thereto, and, in a settlement or compromise which does not involve only the payment of money by the Indemnifier, without the prior written consent of the Indemnified Party which consent shall not be unreasonably withheld. 

 

	 	(c)	 In the event the Indemnifier does not notify the Indemnified Party within ten (10) Business Days after the Indemnified Party has received a Notice of Claim that the
Indemnifier is assuming the defence thereof, then the Indemnified Party shall have the right, subject to the provisions of this Section, to undertake the defence, compromise or settlement of such claim for the account of the Indemnifier. Unless and
until the 

  

 30 

	 	 
Indemnifier assumes the defence of any claim, the Indemnifier shall advance to the Indemnified Party any of its reasonable attorneys’ fees and other
costs and expenses incurred in connection with the defence of any such action or proceeding. Each Indemnified Party shall agree in writing prior to any such advance that, in the event it receives any such advance, such Indemnified Party shall
reimburse the Indemnifier for such fees, costs and expenses to the extent that it shall be determined that it was not entitled to indemnification under this Section 8.8. 

  

	 	(d)	In the event that the Indemnifier undertakes the defence of any claim, the Indemnifier will keep the Indemnified Party advised as to all material developments in connection with
such claim, including, but not limited to, promptly furnishing the Indemnified Party with copies of all material documents filed or served in connection therewith. 

  

	 	(e)	If any Indemnity Claim is of a nature such that the Indemnified Party is legally bound or required by Applicable Law to make a payment to a third party with respect to such
Indemnity Claim before the completion of settlement negotiations or related legal proceedings, including the posting of any security to stay any process of execution or judgment, then the Indemnifier will be obligated to make such payment or post
security therefor on behalf of the Indemnified Party. If the Indemnifier fails to do so, the Indemnified Party may make such payment or post security therefor and the Indemnifier will, forthwith after demand by the Indemnified Party, reimburse the
Indemnified Party for any such payment or cause the security to be replaced and released. If the amount of any liability of the Indemnified Party under the Indemnity Claim in respect of which such a payment was made, as finally determined, is less
than the amount which was paid by the Indemnifier to the Indemnified Party, the Indemnified Party will, forthwith after receipt of the difference from a third party, pay the amount of such difference to the Indemnifier. 

  

	8.9	Limitations on Amount 

  
 Notwithstanding any other provision in this Agreement and notwithstanding any inaccuracy or incorrectness of any provision in this Agreement (including the Schedules),
the obligations of the Vendors in respect of all claims for any inaccuracy in or breach of any representation or warranty under Section 4.1 will be limited to the aggregate of the Initial Purchase Price and the Subsequent Purchase Price for all
Outstanding Vessels paid by the Purchaser and no individual claim will be made against the Vendors unless such claim exceeds $100,000; provided that any claims that relate to a particular Vessel or Vendor will be limited to the Initial Purchase
Price allocated to that Vendor or the applicable Subsequent Purchase Price, as the case may be. 
  

	8.10	Election 

  
 Except with respect to fraud, wilful misconduct or bad faith by or on behalf of an indemnifying Party, from and after the Initial Time of Closing or, with respect to any Outstanding Vessel, from and after the
applicable Subsequent Time of Closing, the indemnification remedies contained in this Section 8 shall be the exclusive remedies for damages of the Parties for any breach of or under this Agreement, or any document provided pursuant to this
Agreement, and the exercise by any Party of any of its rights under 

  

 31 

 
this Section 8 shall be deemed to be an election of remedies and shall prejudice, and constitute a waiver of, any other right or remedy that such Party may
be entitled to exercise at law, in equity or otherwise. 
  

	9.	TERMINATION AND WAIVER 

  

	9.1	Termination for Failure to Consummate Initial Public Offering 

  
 In the event the Initial Public Offering is not consummated by September 30, 2005, this Agreement shall terminate on and as of that date without any further action by any
Party and no Party shall by entitled to damages or to any other compensation or reimbursement of expenses as a result of such termination. 
  

	9.2	Termination Upon Termination of a Vessel Sale Agreement 

  
 If a Vessel Sale Agreement is terminated or cancelled for any reason whatsoever, then this Agreement shall be deemed to be terminated in respect of the Vendor which is
party to such Vessel Sale Agreement, without any further action by either the Purchaser or that Vendor. 
  

	9.3	Effect of Waiver 

  
 A waiver by either the Purchaser or any Vendor of any one or more of the conditions referred to Section 6.1 or Section 6.2 will be without prejudice to its right to terminate in respect of any other non-fulfillment of
any other of the conditions. 
  

	9.4	Without Prejudice 

  
 Termination by the Purchaser pursuant to Section 6.1 or by any Vendor pursuant to Section 6.2 will be without prejudice to the right, subject to the limitations, exceptions and restrictions set out in this Agreement,
to recover Losses for any misrepresentations, breach of warranty or non-fulfillment of any covenant or agreement of the other. 
  

	10.	MISCELLANEOUS 

  

	10.1	Notices 

  
 Any notice, request, determination, demand or communication required or permitted to be given under this Agreement will be in writing and delivered by hand, facsimile transmission or prepaid registered mail (return
receipt requested) to the Party to which it is to be given as follows: 
  
 To a Vendor or SCLL: 
  
 [Vendor Name] 
 [c/o] Seaspan Container Lines Limited 
 6
Floor Meliza Court 
 229 Arch Makarios III Avenue 
 PO Box 54117 
 3721 Limassol 
 Cyprus 
  

 32 

 Attention: Director / Stichling Hahn Hilbrich 
  
 Facsimile No.: 357.2558.3254 
  
 With a copy to the Manager: 
  
 Seaspan Ship Management Ltd. 
 200 Granville Street 
 Suite 2600 

Vancouver, British Columbia 
 V6C 1S4

  
 Attention: Chief Financial Officer 
  
 Facsimile No.: 604.638.2595 
  
 To the Purchaser: 
  
 Seaspan Corporation 
 200 Granville Street 
 Suite 2600 

Vancouver, British Columbia 
 V6C 1S4

  
 Attention: Chief Financial Officer 
  
 Facsimile No.: 604.482.8781 
  
 or to such other address as a Party may specify by notice given in accordance with this
section. Any such notice, request, demand or communication given as aforesaid will be deemed to have been given, in the case of delivery by hand, when delivered, in the case of delivery by facsimile transmission, when a legible facsimile is received
by the recipient if received before 5:00 p.m. on a Business Day or on the next Business Day if such facsimile is received on a day which is not a Business Day or after 5:00 p.m. on a Business Day, and in the case of delivery by prepaid registered
mail, as aforesaid, on the date received. In the event of discontinuance of postal service due to strike, lockout, labour disturbance or otherwise, notices, demands, requests and communications will be delivered by hand or by facsimile transmission.

  

	10.2	Further Assurances 

  
 From time to time subsequent to each Closing Date, the Purchaser and the Vendor of the Purchased Assets sold on such Closing Date, at the expense of the requesting party (unless such documents are to be delivered
pursuant to Section 2.6(a), in which case it shall be at the Vendor’s expense), shall promptly execute and deliver all such documents, including, without limitation, all such additional conveyances, transfers, consents and other assurances and
do all such other acts and things as the requesting party, acting reasonably, may from time to time request be executed or done in order to better evidence or perfect or effectuate any provision of this Agreement or of any agreement or other
document executed pursuant to this Agreement or any of the respective obligations intended to be created hereby or thereby. 
  

 33 

	10.3	Entire Agreement 

  
 This Agreement, including any schedules and exhibits hereto, and each of the Vessel Sale Agreements, constitute the entire agreement between SCLL, the Vendors and the Purchaser pertaining to the purchase and sale of
the Purchased Assets and supersedes all prior agreements, undertakings, negotiations and discussions, whether oral or written, of any Vendor and the Purchaser and there are no warranties, representations, covenants, obligations or agreements between
any Vendor (or any Affiliate thereof) and the Purchaser except as set forth in this Agreement. 
  

	10.4	Assignment 

  
 None of the Vendors may assign any of their respective benefits or rights, and no Person may assume any of the Vendors’ obligations, under or in respect of this Agreement without the written consent of the
Purchaser, which consent shall not be unreasonably withheld or delayed. The Purchaser may not assign any of its benefits or rights, and no Person may assume any of the Purchaser’s obligations, under or in respect of this Agreement without the
written consent of all of the Vendors, which consent shall not be unreasonably withheld or delayed. 
  

	10.5	Waiver and Amendment 

  
 Except as expressly provided in this Agreement, no amendment or waiver of it will be binding unless made in writing by the Party to be bound by such amendment or waiver. No waiver of any provision or any portion of
any provision, of this Agreement will constitute a waiver of any other part of the provision or any other provision of this Agreement nor a continuing waiver unless otherwise expressly provided. 
  

	10.6	Severability 

  
 Each provision of this Agreement is several. If any provision of this Agreement is or becomes illegal, invalid or unenforceable in any jurisdiction, the illegality, invalidity or unenforceability of that provision
will not affect: 
  

	 	(a)	the legality, validity or enforceability of the remaining provisions of this Agreement; or 

  

	 	(b)	the legality, validity or enforceability of that provision in any other jurisdiction. 

  
 except that if: 
  

	 	(c)	on the reasonable construction of this Agreement as a whole, the applicability of the other provision presumes the validity and enforceability of the particular provision, the other
provision will be deemed also to be invalid or unenforceable; and 

  

	 	(d)	as a result of the determination by a court of competent jurisdiction that any part of this Agreement is unenforceable or invalid and, as a result of this Section 10.6, the basic
intentions of the parties in this Agreement are entirely frustrated, the parties will use all reasonable efforts to amend, supplement or otherwise vary this Agreement to confirm their mutual intention in entering into this Agreement.

  

 34 

	10.7	Third Party Beneficiaries 

  
 The Parties intend that this Agreement will not benefit or create any right or cause of action in, or on behalf of, any other Person and no other Person, will be entitled
to rely on the provisions of this Agreement in any action, suit, proceeding, hearing or other forum. Each Vendor is and will be deemed to be acting as agent or trustee on behalf of and for the benefit of each of that Vendors’ Indemnified
Persons and the Purchaser is and will be deemed to be acting as agent or trustee on behalf of and for the benefit of each of the Purchaser’s Indemnified Persons. 
  

	10.8	 Submission to Jurisdiction 

  
 Subject to Section 10.9, each of the Parties irrevocably submits to the exclusive jurisdiction of the courts of British Columbia in any Permitted Action and each party to
this Agreement waives, and will not assert by way of motion, as a defence, or otherwise, in any Permitted Action, any claim that: 
  

	 	(a)	that Party is not subject to the jurisdiction of the courts of British Columbia; 

  

	 	(b)	the Permitted Action is brought in an inconvenient forum; 

  

	 	(c)	the venue of the Permitted Action is improper; or 

  

	 	(d)	any subject matter of the Permitted Action may not be enforced in or by the courts of British Columbia. 

  
 In any suit or action brought to obtain a judgment for the recognition or enforcement of any final judgment rendered in a Permitted Action,
no party to this Agreement will seek any review with respect to the merits of any Permitted Action, whether or not that party appears in or defends the Permitted Action. 
  

	10.9	Dispute Resolution 

  
 If there is a dispute or other failure to agree arising out of or in connection with this Agreement, a Party may give notice to the other Party requiring that the dispute or issue be referred to a senior officer of
each Party that has been designated to represent such Party hereunder. When this notice is given, each Party will cause its designated officer to promptly begin discussions with each other with a view to settling the dispute or issue. A unanimous
decision of the designated officers which is communicated by notice from them to the Parties will be binding on the Parties. If the designated officers do not communicate a unanimous decision by notice within 15 days after the date of the notice
referring the matter to them, then the dispute or issue will be submitted: (a), in the case of a dispute with respect to Sections 3.7 or 3.9 to arbitration under the Commercial Arbitration Act (British Columbia); and (b) in all other cases to the
courts of British Columbia. In the case of any arbitration, the place of the arbitration will be Vancouver, British Columbia and the award of the arbitrator will be final and binding on the Parties. 
  

	10.10 	Counterparts 

  
 This Agreement may be signed in counterparts and each such counterpart will constitute an original document and such counterparts, taken together, will constitute one and the same instrument. 
  

 35 

	10.11 	Enurement 

  
 This Agreement will enure to the benefit of and will be binding upon the parties and their respective successors and any Affiliate of the Purchaser which is an assignee of the Purchaser as contemplated in Section
10.4. 
  
 IN WITNESS WHEREOF the parties have executed this Agreement as of the
day and year first above written. 
  

									
	SEASPAN CORPORATION	 	 	 	 	 	 
				
	 	 	 	 	 	 	 
	 Per:
	 	Authorised Signatory	 	 	 	 	 	 
			
	CSCL HAMBURG SHIPPING COMPANY LIMITED	 	 	 	CSCL CHIWAN SHIPPING COMPANY LIMITED
			
	 	 	 	 	 
	 Per:
	 	Authorised Signatory	 	 	 	 Per:
	 	Authorised Signatory
			
	CSCL NINGBO SHIPPING COMPANY LIMITED	 	 	 	CSCL DALIAN SHIPPING COMPANY LIMITED
			
	 	 	 	 	 
	 Per:
	 	Authorised Signatory	 	 	 	 Per:
	 	Authorised Signatory
			
	CSCL FELIXSTOWE SHIPPING COMPANY LIMITED	 	 	 	CLORINA MARINE COMPANY LIMITED
			
	 	 	 	 	 
	 Per:
	 	Authorised Signatory	 	 	 	 Per:
	 	Authorised Signatory
			
	ELIA SHIPPING COMPANY LIMITED	 	 	 	VANCOUVER SHIPPING COMPANY LIMITED
			
	 	 	 	 	 
	 Per:
	 	Authorised Signatory	 	 	 	 Per:
	 	Authorised Signatory

  

 36 

									
	TOFINO SHIPPING COMPANY LIMITED	 	 	 	NOOTKA SHIPPING COMPANY LIMITED
			
	 	 	 	 	 
	 Per:
	 	Authorised Signatory	 	 	 	 Per:
	 	Authorised Signatory
			
	NANAIMO SHIPPING COMPANY LIMITED	 	 	 	BURRARD SHIPPING COMPANY LIMITED
			
	 	 	 	 	 
	 Per:
	 	Authorised Signatory	 	 	 	 Per:
	 	Authorised Signatory
			
	SEASPAN KING SHIPPING COMPANY LIMITED	 	 	 	SEASPAN QUEEN SHIPPING COMPANY LIMITED
			
	 	 	 	 	 
	 Per:
	 	Authorised Signatory	 	 	 	 Per:
	 	Authorised Signatory

  

									
			
	SEASPAN KNIGHT SHIPPING COMPANY LIMITED	 	 	 	SEASPAN BISHOP SHIPPING COMPANY LIMITED
			
	 	 	 	 	 
	 Per:
	 	Authorised Signatory	 	 	 	 Per:
	 	Authorised Signatory
			
	SEASPAN CASTLE SHIPPING COMPANY LIMITED	 	 	 	SEASPAN PAWN SHIPPING COMPANY LIMITED
			
	 	 	 	 	 
	 Per:
	 	Authorised Signatory	 	 	 	 Per:
	 	Authorised Signatory
			
	SEASPAN ACE SHIPPING COMPANY LIMITED	 	 	 	SEASPAN EAGLE SHIPPING COMPANY LIMITED
			
	 	 	 	 	 
	 Per:
	 	Authorised Signatory	 	 	 	 Per:
	 	Authorised Signatory
			
	SEASPAN BIRDIE SHIPPING COMPANY LIMITED	 	 	 	HEMLOCK SHIPPING COMPANY LIMITED
			
	 	 	 	 	 
	 Per:
	 	Authorised Signatory	 	 	 	 Per:
	 	Authorised Signatory

  

 37 

									
	SPRUCE SHIPPING COMPANY LIMITED	 	 	 	SEASPAN CONTAINER LINES LIMITED
			
	 	 	 	 	 
	 Per:
	 	Authorised Signatory	 	 	 	 Per:
	 	Authorised Signatory

  
  

 38 

  
 Schedule 1 

 
 LIST OF VENDORS 
  

	1.	CSCL Hamburg Shipping Company Limited 

  

	2.	CSCL Chiwan Shipping Company Limited 

  

	3.	CSCL Ningbo Shipping Company Limited 

  

	4.	CSCL Dalian Shipping Company Limited 

  

	5.	CSCL Felixstowe Shipping Company Limited 

  

	6.	Clorina Marine Company Limited 

  

	7.	Elia Shipping Company Limited 

  

	8.	Vancouver Shipping Company Limited 

  

	9.	Tofino Shipping Company Limited 

  

	10.	Nootka Shipping Company Limited 

  

	11.	Nanaimo Shipping Company Limited 

  

	12.	Burrard Shipping Company Limited 

  

	13.	Seaspan King Shipping Company Limited 

  

	14.	Seaspan Queen Shipping Company Limited 

  

	15.	Seaspan Knight Shipping Company Limited 

  

	16.	Seaspan Bishop Shipping Company Limited 

  

	17.	Seaspan Castle Shipping Company Limited 

  

	18.	Seaspan Pawn Shipping Company Limited 

  

	19.	Seaspan Ace Shipping Company Limited 

  

	20.	Seaspan Eagle Shipping Company Limited 

  

	21.	Seaspan Birdie Shipping Company Limited 

  

	22.	Hemlock Shipping Company Limited 

  

	23.	Spruce Shipping Company Limited 

  
 Schedule 1A

  
 INITIAL VENDORS AND DELIVERED VESSELS 
  

					
	 Initial Vendor

	  	 Vessel Name

	  	 Flag

	CSCL Hamburg Shipping Company Limited	  	CSCL Hamburg	  	Cyprus
	CSCL Chiwan Shipping Company Limited	  	CSCL Chiwan	  	Cyprus
	CSCL Ningbo Shipping Company Limited	  	CSCL Ningbo	  	Cyprus
	CSCL Dalian Shipping Company Limited	  	CSCL Dalian	  	Cyprus
	CSCL Felixstowe Shipping Company Limited	  	CSCL Felixstowe	  	Cyprus
	Clorina Marine Company Limited	  	CSCL Oceania	  	Cyprus
	Elia Shipping Company Limited	  	CSCL Africa	  	Cyprus
	Vancouver Shipping Company Limited	  	CSCL Vancouver	  	Cyprus
	Tofino Shipping Company Limited	  	CSCL Sydney	  	Cyprus
	Nootka Shipping Company Limited	  	CSCL New York	  	Cyprus

  
 Schedule 1B

  
 SUBSEQUENT VENDORS AND OUTSTANDING VESSELS

  

			
	 Subsequent Vendor

	  	 Proposed Vessel Name

	 Nanaimo Shipping Company Limited
	  	CSCL Melbourne
	 Burrard Shipping Company Limited
	  	CSCL Brisbane
	 Seaspan King Shipping Company Limited
	  	CP Kanha
	 Seaspan Queen Shipping Company Limited
	  	CP Corbett
	 Seaspan Knight Shipping Company Limited
	  	Containership Banyan
	 Seaspan Bishop Shipping Company Limited
	  	Lykes Merchant
	 Seaspan Castle Shipping Company Limited
	  	TMM Morelos
	 Seaspan Pawn Shipping Company Limited
	  	Containership Margosa
	 Seaspan Ace Shipping Company Limited
	  	Lykes Victor
	 Seaspan Eagle Shipping Company Limited
	  	TMM Nuevo Leon
	 Seaspan Birdie Shipping Company Limited
	  	Containership Cassia
	 Hemlock Shipping Company Limited
	  	CSCL Zeebrugge
	 Spruce Shipping Company Limited
	  	CSCL Long Beach

  
 Schedule 1C

  
 TIME CHARTERS 
  

							
	 Vendor

	  	 Charterer

	  	 Date of Charter

	  	 Vessel/Hull No.

	CSCL Hamburg Shipping Company Limited	  	China Shipping (Group) Company	  	July 28, 2000	  	CSCL Hamburg/Hull No. 1342
				
	CSCL Chiwan Shipping Company Limited	  	China Shipping (Group) Company	  	July 28, 2000	  	CSCL Chiwan/Hull No. 1343
				
	CSCL Ningbo Shipping Company Limited	  	China Shipping (Group) Company	  	July 28, 2000	  	CSCL Ningbo/Hull No. 1347
				
	CSCL Dalian Shipping Company Limited	  	China Shipping (Group) Company	  	July 28, 2000	  	CSCL Dalian/Hull No.1348
				
	CSCL Felixstowe Shipping Company Limited	  	China Shipping (Group) Company	  	July 28, 2000	  	CSCL Felixstowe/Hull No. 1349
				
	Clorina Marine Company Limited	  	China Shipping (Group) Company	  	December 25, 2002	  	CSCL Oceania/Hull No. 1491
				
	Elia Shipping Company Limited	  	China Shipping (Group) Company	  	December 25, 2002	  	CSCL Africa/Hull No. 1492
				
	Vancouver Shipping Company Limited	  	China Shipping (Group) Company	  	December 25, 2002	  	CSCL Vancouver/Hull No. 1493
				
	Tofino Shipping Company Limited	  	China Shipping (Group) Company	  	December 25, 2002	  	CSCL Sydney/Hull No. 1494
				
	Nootka Shipping Company Limited	  	China Shipping (Group) Company	  	January 27, 2003	  	CSCL New York/Hull No. 1498
				
	Nanaimo Shipping Company Limited	  	China Shipping (Group) Company	  	January 27, 2003	  	CSCL Melbourne/Hull No. 1499
				
	Burrard Shipping Company Limited	  	China Shipping (Group) Company	  	January 27, 2003	  	CSCL Brisbane/Hull No. 1500
				
	Seaspan King Shipping Company Limited	  	Lykes Lines Limited LLC	  	August 12, 2003	  	CP Kanha/Hull No. 1539
				
	Seaspan Queen Shipping Company Limited	  	Lykes Lines Limited LLC	  	August 12, 2003	  	CP Corbett/Hull No. 1540
				
	Seaspan Knight Shipping Company Limited	  	Lykes Lines Limited LLC	  	August 12, 2003	  	Containership Banyan/Hull No. 1541
				
	Seaspan Bishop Shipping Company Limited	  	Lykes Lines Limited LLC	  	August 12, 2003	  	Lykes Merchant/Hull No. 1542
				
	Seaspan Castle Shipping Company Limited	  	Lykes Lines Limited LLC	  	August 12, 2003	  	TMM Morelos/Hull No. 1543
				
	Seaspan Pawn Shipping Company Limited	  	Lykes Lines Limited LLC	  	August 12, 2003	  	Containership Margosa/Hull No. 1544
				
	Seaspan Ace Shipping Company Limited	  	Lykes Lines Limited LLC	  	August 12, 2003	  	Lykes Victor/Hull No. 1550

							
	Seaspan Eagle Shipping Company Limited	  	Lykes Lines Limited LLC	  	August 12, 2003	  	TMM Nuevo Leon/ Hull No. 1551
				
	Seaspan Birdie Shipping Company Limited	  	Lykes Lines Limited LLC	  	August 12, 2003	  	Containership Cassia/Hull No. 1552
				
	Hemlock Shipping Company Limited	  	China Shipping (Group) Company	  	April 10, 2004	  	CSCL Zeebrugge/Hull No. 1566
				
	Spruce Shipping Company Limited	  	China Shipping (Group) Company	  	April 10, 2004	  	CSCL Long Beach/Hull No. 1568

  
 Schedule 1.1A

  
 EXISTING CREDIT FACILITIES 
  

					
	 Existing Credit Facilities

	  	Date of Existing Credit
Facility Agreement

	 	Amount of Existing
Credit Facilities

	CSCL Hamburg Shipping Company Limited, CSCL Chiwan Shipping Company Limited, CSCL Ningbo Shipping Company Limited, CSCL Dalian Shipping Company Limited and CSCL Felixstowe Shipping Company
Limited as owners, Fortis Capital Corp. as arranger, facility agent and advisor, the lenders as defined in the credit facility agreement and Fortis Bank (Nederland) N.V. as swap agent	  	November 2, 2004	 	US$165,000,000
			
	CSCL Hamburg Shipping Company Limited, CSCL Chiwan Shipping Company Limited, CSCL Ningbo Shipping Company Limited, CSCL Dalian Shipping Company Limited and CSCL Felixstowe Shipping Company
Limited as owners, NIB Capital Bank N.V. and The Governor and Company of the Bank of Scotland as lenders and NIB Capital Bank N.V. as facility agent	  	November 2, 2004	 	US$25,000,000
			
	Clorina Marine Company Limited and Elia Shipping Company Limited as owners, Credit Suisse and DVB Bank AG as joint arrangers, the lenders as defined in the credit facility agreement, DVB Bank AG
as facility agent and DVB Bank AG as swap bank	  	November 8, 2004	 	US$130,000,000
			
	Clorina Marine Company Limited and Elia Shipping Company Limited as owners, DVB Bank AG and The Governor and Company of the Bank of Scotland as lenders, DVB Bank AG as facility agent and HBOS
Treasury Services PLC as swap bank	  	November 12, 2004	 	US$20,000,000
			
	Vancouver Shipping Company Limited, Tofino Shipping Company Limited, Nootka Shipping Company Limited, Nanaimo Shipping Company Limited and Burrard Shipping Company Limited as owners, The
Export-Import Bank of Korea and Fortis Capital Corp. as joint arrangers, The Export-Import Bank of Korea, Fortis Capital Corp. and NIB Capital Bank N.V. as original lenders, Fortis Capital Corp. as facility agent and advisor and Fortis Bank
N.V./S.A., New York Branch as swap agent	  	November 15, 2004
(supplemental
agreement relating
to a facility
agreement dated
May 12, 2003)	 	US$172,600,000
			
	Vancouver Shipping Company Limited, Tofino Shipping Company Limited, Nootka Shipping Company Limited, Nanaimo Shipping Company Limited and Burrard Shipping Company Limited as owners and Fortis
Capital Corp. as lender and agent	  	November 18, 2004
(amending and
restating the facility
agreement dated
May 12, 2003)	 	US$20,000,000
			
	Hemlock Shipping Company Limited and Spruce Shipping Company Limited as owners, The Export-Import Bank of Korea and Fortis Capital Corp. as joint arrangers, the Lenders as defined in the credit
facility agreement, Fortis Capital Corp. as facility agent and advisor and Fortis Bank N.V./S.A., New York Branch as swap agent	  	November 15, 2004	 	US$152,891,200

  

 47 

					
	Seaspan King Shipping Company Limited, Seaspan Queen Shipping Company Limited, Seaspan Knight Shipping Company Limited, Seaspan Bishop Shipping Company Limited, Seaspan Castle Shipping Company
Limited, Seaspan Pawn Shipping Company Limited, Seaspan Ace Shipping Company Limited, Seaspan Eagle Shipping Company Limited and Seaspan Birdie Shipping Company Limited as owners, The Export-Import Bank of Korea and Fortis Capital Corp. as joint
arrangers, the Lenders as defined in the credit facility agreement, Fortis Capital Corp. as facility agent and Fortis (USA) Finance LLC as swap agent	  	November 10, 2003	  	US$327,600,000
			
	Seaspan King Shipping Company Limited, Seaspan Queen Shipping Company Limited, Seaspan Knight Shipping Company Limited, Seaspan Bishop Shipping Company Limited, Seaspan Castle Shipping Company
Limited, Seaspan Pawn Shipping Company Limited, Seaspan Ace Shipping Company Limited, Seaspan Eagle Shipping Company Limited and Seaspan Birdie Shipping Company Limited as owners, Maas Capital Investments B.V., BFC Assets, Inc. and NIB Capital Bank
N.V. as lenders, Maas Capital Investments B.V. as facility agent and Fortis Bank (Nederland) N.V. as paying agent	  	December 31, 2003	  	US$36,000,000

  
 Schedule 1.1B

  
 SHIPBUILDING CONTRACTS 
  

					
	 Vendor

	  	Date of Contract

	  	 Vessel/Hull No.

	CSCL Hamburg Shipping Company	  	March 2, 2000	  	CSCL Hamburg/Hull No. 1342
	CSCL Chiwan Shipping Company Limited	  	March 2, 2000	  	CSCL Chiwan/Hull No. 1343
	CSCL Ningbo Shipping Company Limited	  	March 2, 2000	  	CSCL Ningbo/Hull No. 1347
	CSCL Dalian Shipping Company	  	March 2, 2000	  	CSCL Dalian/Hull No.1348
	CSCL Felixstowe Shipping Company Limited	  	March 2, 2000	  	CSCL Felixstowe/Hull No. 1349
	Clorina Marine Company Limited	  	December 25, 2002	  	CSCL Oceania/Hull No. 1491
	Elia Shipping Company Limited	  	December 25, 2002	  	CSCL Africa/Hull No. 1492
	Vancouver Shipping Company Limited	  	February 4, 2003	  	CSCL Vancouver/Hull No. 1493
	Tofino Shipping Company Limited	  	February 4, 2003	  	CSCL Sydney/Hull No. 1494
	Nootka Shipping Company Limited	  	February 4, 2003	  	CSCL New York/Hull No. 1498
	Nanaimo Shipping Company Limited	  	February 4, 2003	  	CSCL Melbourne/Hull No. 1499
	Burrard Shipping Company Limited	  	February 4, 2003	  	CSCL Brisbane/Hull No. 1500
	Seaspan King Shipping Company Limited	  	July 30, 2003	  	CP Kanha /Hull No. 1539
	Seaspan Queen Shipping Company Limited	  	July 30, 2003	  	CP Corbett/Hull No. 1540
	Seaspan Knight Shipping Company Limited	  	July 30, 2003	  	Containership Banyan/Hull No. 1541
	Seaspan Bishop Shipping Company Limited	  	July 30, 2003	  	Lykes Merchant/Hull No. 1542
	Seaspan Castle Shipping Company Limited	  	July 30, 2003	  	TMM Morelos/Hull No. 1543
	Seaspan Pawn Shipping Company Limited	  	July 30, 2003	  	Containership Margosa/Hull No. 1544
	Seaspan Ace Shipping Company Limited	  	July 30, 2003	  	Lykes Victor/Hull No. 1550
	Seaspan Eagle Shipping Company Limited	  	July 30, 2003	  	TMM Nuevo Leon/ Hull No. 1551
	Seaspan Birdie Shipping Company Limited	  	July 30, 2003	  	Containership Cassia/Hull No. 1552
	Hemlock Shipping Company Limited	  	April 10, 2004	  	CSCL Zeebrugge/Hull No. 1566
	Spruce Shipping Company Limited	  	April 10, 2004	  	CSCL Long Beach/Hull No. 1568

  
 Schedule 2.6

  
 FORM OF VESSEL SALE AGREEMENT 

  
 Schedule 2.8

  
 FORM OF ASSUMPTION AND ASSIGNMENT 

  
 Schedule 3.2

  
 ALLOCATION OF INITIAL PURCHASE PRICE 
  

				
	 Initial Vendor

	  	Allocation of Initial
Purchase Price

	 
	 CSCL Hamburg Shipping Company Limited
	  	8.75	%
	 CSCL Chiwan Shipping Company Limited
	  	8.75	%
	 CSCL Ningbo Shipping Company Limited
	  	9.64	%
	 CSCL Dalian Shipping Company Limited
	  	9.64	%
	 CSCL Felixstowe Shipping Company Limited
	  	9.64	%
	 Clorina Marine Company Limited
	  	14.91	%
	 Elia Shipping Company Limited
	  	14.91	%
	 Vancouver Shipping Company Limited
	  	7.92	%
	 Tofino Shipping Company Limited
	  	7.92	%
	 Nootka Shipping Company Limited
	  	7.92	%
	 	  	
	

	 Total:
	  	100.00	%

  
 Schedule 3.4

  
 SUBSEQUENT PURCHASE PRICE 
  

			
	 Subsequent Vendor

	  	Subsequent Purchase
Price (US Dollars)

	 Nanaimo Shipping Company Limited
	  	52,671,339
	 Burrard Shipping Company Limited
	  	52,671,339
	 Seaspan King Shipping Company Limited
	  	56,893,397
	 Seaspan Queen Shipping Company Limited
	  	56,893,397
	 Seaspan Knight Shipping Company Limited
	  	56,893,397
	 Seaspan Bishop Shipping Company Limited
	  	56,893,397
	 Seaspan Castle Shipping Company Limited
	  	56,893,397
	 Seaspan Pawn Shipping Company Limited
	  	56,893,397
	 Seaspan Ace Shipping Company Limited
	  	56,893,397
	 Seaspan Eagle Shipping Company Limited
	  	56,893,397
	 Seaspan Birdie Shipping Company Limited
	  	56,893,397
	 Hemlock Shipping Company Limited
	  	115,955,819
	 Spruce Shipping Company Limited
	  	115,955,819
	 	  	

	 Total:
	  	849,294,889

  
 Schedule 4.1(d)

  
 CONSENTS AND AUTHORIZATIONS 
  

	1.	Consent of the Builder to the assignment of all rights and benefits, to the extent assignable, under the Ship Building Contract set out in Schedule 1.1 B. 

 

	2.	Consents of the facilities agents or lenders required pursuant to the Existing Credit Facilities to permit the transactions contemplated by the Agreement, including in connection
with the discharge of any of the Existing Credit Facilities Security. 

  

	3.	Filings and consents of the Cyprus Department of Merchant Shipping required in connection with discharge of any of the Existing Credit Facilities Security.1 

  

	4.	Consent of [                    ] to the assignment of [certain Vessel
Warranties], to the extent assignable. 

	1	These filings and consents will be obtained reasonably promptly following the relevant Time of Closing. 

  
 Schedule 4.1(m)

  
 LEGAL PROCEEDINGS 

  
 Schedule 4.1(n)

  
 LICENCES

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00088-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00088-of-00352.parquet"}]]