Document:

Exhibit 4.21

 Exhibit 4.21 
 EXECUTION VERSION 
 Dated 10 October 2008 

 
  

 

					
		 	MiNT LNG III, LTD.	    	(1)
		 	(as Borrower)	    	
			
		 	The Banks and Financial Institutions listed	    	(2)
		 	 in Annex 1
 (as Lenders)
	    	
			
		 	The Banks and Financial Institutions listed	    	(3)
		 	 in Annex 1
 (as Swap Providers)
	    	
			
		 	BNP PARIBAS S.A.	    	(4)
		 	(as Agent)	    	
			
		 	BNP PARIBAS S.A.	    	(5)
		 	(as Security Trustee)	    	
			
		 	and	    	
			
		 	BNP PARIBAS S.A.	    	(6)
		 	(as KEIC Agent)	    	

  
  

DEED OF AMENDMENT AND 
 RESTATEMENT 
 relating to a Loan Agreement of 

US$92,400,000 Buyer Credit and 
 $117,600,000 Commercial Loan for one 
 160,000 cbm LNG carrier Hull
No. 1812 at 
 Samsung Heavy Industries Co., Ltd. 

 
  

 
 

 

 CONTENTS 

 

					
	Clause	  	Page	 
	 1 Definitions
	  	 	1	  
		
	 2 Amendments to the Loan Agreement
	  	 	1	  
		
	 3 Miscellaneous
	  	 	2	  
		
	 Annex 1
	  	 	6	  

 THIS DEED is made on 10 October 2008 BETWEEN: 

 

	(1)	MiNT LNG III, LTD., being a company organised and existing under the laws of the Bahamas whose registered office is at 50 Shirley Street, P.O. Box CB—13937,
Nassau, The Bahamas (the “Borrower”); and 

  

	(2)	the banks and financial institutions listed in Schedule 1 Part 1 in Annex 1, each acting through its office at the address indicated against its name in Schedule 1 Part
1 in Annex 1 (together the “Lenders” and each a “Lender”); and 

  

	(3)	the banks and financial institutions listed in Schedule 1 Part 2 in Annex 1, each acting through its office at the address indicated against its name in Schedule 1 Part
2 in Annex 1 (together the “Swap Providers” and each a “Swap Provider”); and 

  

	(4)	BNP PARIBAS S.A., acting as agent with its registered office at 16 boulevard des Italiens 75009 Paris and registration number 662 042 449 RSC Paris for the
Lenders and the Swap Providers (in that capacity the “Agent”); and 

  

	(5)	BNP PARIBAS S.A., acting as security trustee through its office at 16 boulevard des Italiens 75009 Paris and registration number 662 042 449 RSC Paris for the
Lenders and the Swap Providers (in that capacity the “Security Trustee”); and 

  

	(6)	BNP PARIBAS S.A., acting as agent through its office at 24/F, Taepyeongno Building 310, Taepyeongno 2-ga, Jung-gu, Seoul 100-767, for the Lenders under the KEIC
Buyer Credit Policy (as this term is defined in Annex 1) (in that capacity the “KEIC Agent”). 

 WHEREAS:

  

	(A)	By a loan agreement (the “Loan Agreement”) dated 11 September 2008 and made between the Borrower, the Lenders, the Agent, the KEIC Agent, the
Security Trustee and the Swap Providers, pursuant to which the Lenders agreed (inter alia) to loan to the Borrower, upon the terms and conditions therein contained, a buyer credit tranche of up to the lesser of (i) forty-four per cent.
(44%) of eighty per cent. (80%) of the Total Project Cost (as defined in Annex 1) and (ii) ninety two million four hundred thousand Dollars ($92,400,000) and a commercial tranche of up to the lesser of (i) fifty-six per cent.
(56%) of eighty per cent. (80%) of the Total Project Cost (as defined in Annex 1) and (ii) one hundred and seventeen million six hundred thousand Dollars ($117,600,000) to assist in financing the 160,000 cbm LNG carrier with hull
number 1812 at Samsung Heavy Industries Co., Ltd. 

  

	(B)	The parties to this Deed wish to amend and restate the Loan Agreement, as set out herein, to take effect from the date of this Deed. 

NOW IT IS HEREBY AGREED as follows: 
  

	1	Definitions 

  

	1.1	In this Deed: 

“Dollars” and “$” means the lawful currency of the United States of America from time to time; and

 “Restated Loan Agreement” means the agreement as set out in Annex 1. 

 

	2	Amendments to the Loan Agreement 

  

	2.1	The parties to this Deed hereby confirm that with effect from the date of this Deed, but without prejudice to any accrued rights and obligations, the Loan Agreement
shall be amended and restated in its entirety by and shall be construed in accordance with the Restated Loan Agreement and the parties to this Deed agree that they are and shall be bound by all of the provisions of the Restated Loan Agreement.

  
 1 

	3	Miscellaneous 

  

	3.1	Clauses 14 and 17 of the Loan Agreement shall, mutatis mutandis, be incorporated in this Deed as if set out herein. 

 

	3.2	This Deed may be executed in any number of counterparts, to the effect that any single counterpart or set of counterparts taken together executed and delivered by all
of the parties shall constitute one and the same instrument. 

 IN WITNESS whereof this Deed is executed by the parties on
the day and year first above written. 

  
 2 

 EXECUTION PAGE - AMENDMENT AND RESTATEMENT AGREEMENT 

 

			
	 EXECUTED AS A DEED
	 	)
	 by and on behalf of
	 	)
	 MiNT LNG III, LTD.
	 	) /s/ [ILLEGIBLE]
		 	  

	 (as Borrower)
	 	)
	 by YUJI ISHIMARU
	 	)
	 in the presence of:
	 	
		
	 Chin Peter
	 	
	 1-12-32 Akasaka
	 	
	 Tokyo Japan
	 	
	 Attorney
	 	
		
	 EXECUTED AS A DEED
	 	)
	 by and on behalf of
	 	)
	 BNP PARIBAS S.A.
	 	) /s/ Patricia Lormeau
		 	  

	 (as a Lender and a Swap Provider)
	 	) Patricia LORMEAU
	 by
	 	)
	 in the presence of:
	 	
	 /s/ A. Renaudin Durand-Ruel
	 	
	  
	 	
	 A. RENAUDIN DURAND-RUEL
	 	
		
	 EXECUTED AS A DEED
	 	)
	 by and on behalf of
	 	)
	 CALYON
	 	) /s/ [ILLEGIBLE]
		 	  

	 (as a Lender and a Swap Provider)
	 	)
	 by
	 	)
	 in the presence of:
	 	
		
	 EXECUTED AS A DEED
	 	)
	 by and on behalf of
	 	)
	 DNB NOR BANK ASA
	 	) /s/ [ILLEGIBLE]
		 	  

	 (as a Lender and a Swap Provider)
	 	) [ILLEGIBLE]
	 by
	 	)
	 in the presence of:
	 	
	 /s/ Eliza Mason
	 	
	  
	 	
	 ELIZA MASON
	 	

  
 3 

			
	 EXECUTED AS A DEED
	 	)
	 by and on behalf of
	 	)
	 SOCIETE GENERALE
	 	) /s/ [ILLEGIBLE]
		 	  

	 (as a Lender and a Swap Provider)
	 	)
	 by
	 	)
	 in the presence of: ELSA GAMBARDELLA

  SG HOUSE, 41 TOWER HILL

  LONDON EC3N 4SG
	 	
		
	 EXECUTED AS A DEED
	 	)
	 by and on behalf of
	 	)
	 THE BANK OF TOKYO-MITSUBISHI UFJ, LTD.
	 	) /s/ [ILLEGIBLE]
		 	  

	 (as a Lender and a Swap Provider)
	 	) [ILLEGIBLE]
	 by
	 	)
	 in the presence of: MASAYUKI FUJIKI
	 	
		
	 EXECUTED AS A DEED
	 	)
	 by and on behalf of
	 	)
	 SUMITOMO MITSUI BANKING CORPORATION
	 	) /s/ [ILLEGIBLE]
		 	  

	 BRUSSELS BRANCH
	 	)
	 (as a Lender)
	 	)
	 by
	 	)
	 in the presence of:
	 	
	 /s/ Eliana Miliou
	 	
	  
	 	
	 ELIANA MILIOU
	 	
	 NORTON ROSE LLP
	 	
		
	 EXECUTED AS A DEED
	 	)
	 by and on behalf of
	 	)
	 SMBC CAPITAL MARKETS, INC.
	 	) /s/ [ILLEGIBLE]
		 	  

	 (as a Swap Provider)
	 	)
	 by
	 	)
	 in the presence of:
	 	
	 /s/ Eliana Miliou
	 	
	  
	 	
	 ELIANA MILIOU
	 	
	 NORTON ROSE LLP
	 	

  

  
 4 

			
	 EXECUTED AS A DEED
	 	)
	 by and on behalf of
	 	)
	 BNP PARIBAS S.A.
	 	) /s/ Patricia Lormeau
		 	  

	 (as Agent)
	 	) Patricia LORMEAU
	 by
	 	)
	 in the presence of:
	 	
	 /s/ A. Renaudin Durand-Ruel
	 	
	  
	 	
	 A. RENAUDIN DURAND-RUEL
	 	
		
	 EXECUTED AS A DEED
	 	)
	 by and on behalf of
	 	)
	 BNP PARIBAS S.A.
	 	) /s/ Patricia Lormeau
		 	  

	 (as the Security Trustee)
	 	) Patricia LORMEAU
	 by
	 	)
	 in the presence of:
	 	
	 /s/ A. Renaudin Durand-Ruel
	 	
	  
	 	
	 A. RENAUDIN DURAND-RUEL
	 	
		
	 EXECUTED AS A DEED
	 	)
	 by and on behalf of
	 	)
	 BNP PARIBAS S.A.
	 	) /s/ Patricia Lormeau
		 	  

	 (as the KEIC Agent)
	 	) Patricia LORMEAU
	 by
	 	)
	 in the presence of:
	 	
	 /s/ A. Renaudin Durand-Ruel
	 	
	  
	 	
	 A. RENAUDIN DURAND-RUEL
	 	

  
 5 

 Annex 1 
 RESTATED LOAN AGREEMENT 

  
 6 

 Dated 11 September
2008 
  
  

(as amended and restated by a Deed of Amendment 

and Restatement dated 10 October 2008) 

 
  

MiNT LNG III, LTD. 
 (as Borrower) 
 and 

The Banks and Financial Institutions listed herein as Lenders 

(as Lenders) 

and 
 The
Banks and Financial Institutions listed herein 
 (as Swap Providers) 

and 
 BNP
PARIBAS S.A. 
 (as Agent) 
 and 
 BNP PARIBAS S.A. 

(as Security Trustee) 
 and 
 BNP PARIBAS S.A. 

(as KEIC Agent) 
 US$92,400,000 BUYER CREDIT AND 
 US$117,600,000 COMMERCIAL LOAN for one

 160,000 cbm LNG CARRIER Hull No 1812 at 
 SAMSUNG HEAVY INDUSTRIES CO., LTD. 
  
 

 

					
	CONTENTS	  	Page	 
	 1 Definitions and Interpretation
	  	 	2	  
		
	 2 The Loan and its Purpose
	  	 
	1920
	 
 
		
	 3 Conditions precedent and subsequent for the Loan
	  	 	23	  
		
	 4 Representations and Warranties
	  	 	25	  
		
	 5 Repayment and Prepayment
	  	 	30	  
		
	 6 Interest
	  	 	35	  
		
	 7 Fees
	  	 	36	  
		
	 8 Security, Accounts and Application of Moneys
	  	 	38	  
		
	 9 Covenants
	  	 	41	  
		
	 10 Events of Default
	  	 	6466	  
		
	 11 Set-Off and Lien
	  	 	6870	  
		
	 12 Assignment and Transfer
	  	 	6971	  
		
	 13 Payments, Reserve Requirements and Illegality
	  	 	7173	  
		
	 14 Communications
	  	 	7577	  
		
	 15 General Indemnities
	  	 	7678	  
		
	 16 Miscellaneous
	  	 	7880	  
		
	 17 Law and Jurisdiction
	  	 	8486	  
		
	 Schedule 1 Part I: The Lenders, the Commitments and the Proportionate Shares
	  	 	8587	  
		
	 Schedule 2 The Vessel
	  	 	9294	  
		
	 Schedule 3 Documents and evidence required as conditions precedent
	  	 	9395	  
		
	 Schedule 4 Form of Transfer Certificate
	  	 	101103	  
		
	 Schedule 5 Form of Drawdown Notice
	  	 	103105	  
		
	 Schedule 6 Calculation of the Mandatory Cost
	  	 	105107	  
		
	 Schedule 7 Contract Instalments and Repayment Profile
	  	 	107109	  
		
	 Schedule 8 Form of Compliance Certificate
	  	 	108111	  
		
	 Exhibit A
	  	 	109112	  

 LOAN FACILITY AGREEMENT (the “Agreement”) 

Dated:                     2008 

BETWEEN: 
  

	(1)	MiNT LNG III, LTD., being a company organised and existing under the laws of the Bahamas whose registered office is at 50 Shirley Street, P.O. Box CB—13937,
Nassau, The Bahamas (the “Borrower”); and 

  

	(2)	the banks and financial institutions listed in Schedule 1 Part 1, each acting through its office at the address indicated against its name in Schedule 1 Part 1
(together the “Lenders” and each a “Lender”); and 

  

	(3)	the banks and financial institutions listed in Schedule 1 Part 2, each acting through its office at the address indicated against its name in Schedule 1 Part 2
(together the “Swap Providers” and each a “Swap Provider”); and 

  

	(4)	BNP PARIBAS S.A., acting as agent with its registered office at 16 boulevard des Italiens 75009 Paris and registration number 662 042 449 RSC Paris for
the Lenders and the Swap Providers (in that capacity the “Agent”); and 

  

	(5)	BNP PARIBAS S.A., acting as security trustee through its office at 16 boulevard des Italiens 75009 Paris and registration number 662 042 449 RSC Paris for
the Lenders and the Swap Providers (in that capacity the “Security Trustee”); and 

  

	(6)	BNP PARIBAS S.A., acting as agent through its office at 24/F, Taepyeongno Building 310, Taepyeongno 2-ga, Jung-gu, Seoul 100-767, for the Lenders under
the KEIC Buyer Credit Policy (in that capacity the “KEIC Agent”). 

 WHEREAS: 

 

	(A)	The Borrower has agreed to purchase the Vessel from the Builder on the terms of the Building Contract and will register the Vessel on delivery on Bahamas flag.

  

	(B)	Each of the Lenders has agreed to advance to the Borrower its Buyer Credit Commitment (aggregating, with all the other Buyer Credit Commitments from the Lenders, up to
an amount equal to the Buyer Credit Maximum Amount) to finance part of the Contract Price (the “Buyer Credit”, as more particularly defined in clause 1.1 below). 

 

	(C)	Each of the Lenders has agreed to advance to the Borrower its Commercial Loan Commitment (aggregating, with all the other Commercial Loan Commitments from the Lenders,
up to an amount equal to the Commercial Loan Maximum Amount) to finance part of the Contract Price and, subject to clause 2.3.3, 100% of the Ancillary Costs (the “Commercial Facility”, as more particularly defined in clause 1.1
below). 

  

	(D)	The Borrower has agreed to time charter the Vessel to Angola LNG Supply Services LLC, a limited liability company duly organised under the laws of the State of
Delaware, USA (the “Time Charterer”), pursuant to the terms of the Time Charter (as defined below). 

  

	(E)	Pursuant to (inter alia) this Agreement, and as a condition precedent to the several obligations of the Lenders to make the Buyer Credit and the Commercial Loan
available to the Borrower, the Borrower has, amongst other things agreed to execute and deliver a first priority mortgage over the Vessel as security for the payment of the Indebtedness. 

 

	(F)	The Lender Finance Parties (as defined below) have agreed to enter into an Intercreditor Deed amongst, inter alios, themselves and the Borrower to, inter alia, regulate
the priorities in respect of each of them under the Security Documents. 

  
 1 

 IT IS AGREED as follows:- 

 

	1	Definitions and Interpretation  

  

	1.1	Definitions 

 In this
Agreement:- 
 “Account Bank” means BNP Paribas S.A., London Branch. 

“Account Bank Fee Letter” means the fee letter in respect of the fee referred to in clause 7.5 and made between the
Borrower and the Account Bank. 
 “Accounts” means all of the Revenue Account, the Dry Docking Reserve Account,
the Retention Account, the Debt Service Reserve Account, the Dividend Lock-up Account and the Distribution Account. 

“Account Charge” means the deed of charge over the Revenue Account, the Dry Docking Reserve Account, the Retention
Account, the Debt Service Reserve Account and the Dividend Lock-up Account in respect of the Vessel, as referred to in clause 8.1.4. 
 “Additional Shareholders’ Equity” has the meaning given to that term in the Letter of Sponsors Undertaking. 
 “Affiliate” means in relation to any entity, a Subsidiary of that entity, a Holding Company of that entity or any other Subsidiary of that Holding Company. 

“Agency Fee Letter” means the fee letter in respect of the fee referred to in clause 7.3 and made between the Borrower
and the Agent. 
 “Ancillary Costs” means costs accruing or incurred or repayments or reimbursements to be made
by the Borrower up to and upon the Delivery Date, or consequent upon Delivery, in respect of: 
  

	 	(a)	the supervision by the Supervisor or its employees of the construction of the Vessel by the Builder which are payable pursuant to the Supervision Agreement or any other
amount payable pursuant to the Supervision Agreement; 

  

	 	(b)	the acquisition of spare parts under the Depot Spares Sharing Agreement; 

  

	 	(c)	all interest, arrangement fees, commitment fees and agency fees in respect of the Loan falling due for payment and/or accruing on or before the Delivery Date;

  

	 	(d)	corporate management fees payable to Mitsui by the Borrower under the Corporate Management Agreement; 

 

	 	(e)	all costs and fees payable by the Borrower in connection with the arrangement of the facility evidenced by this Agreement and the negotiation and finalisation of the
Security Documents to which the Borrower is, or is to be, a party and in relation to the facility generally (including costs and expenses in connection with the registration of the Vessel); 

 

	 	(f)	all costs and expenses incurred by the Borrower in connection with modifications made to the Vessel prior to delivery of the Vessel pursuant to and in accordance with
the Building Contract and the Time Charter; 

  

	 	(g)	all costs and expenses incurred by the Borrower in connection with the Angolanization Agreement; 

 

	 	(h)	the KEIC Insurance Premium; and 

  

	 	(i)	any other costs approved by the Agent in writing (acting on the instructions of the Majority Lenders), 

  
 2 

 but, for the avoidance of doubt, Ancillary Costs shall never cover any item, element or
service to be provided by the Builder pursuant to the Building Contract and which is included in the Contract Price. 

“Ancillary Costs Advance” means a Drawing for the purpose of paying Ancillary Costs incurred by the Borrower and for the
purpose more particularly described in clause 2.3. 
 “Angola LNG” means Angola LNG Ltd, a company established
and existing under the laws of Bermuda. 
 “Angola LNG Project” means the construction and operation of the
approximately one-train liquefaction plant of 5 Mtpa of LNG production capacity constructed or (as the context may require) to be constructed in the vicinity of Kwanda Island in the Zaire Province of Angola, the purchase by the Time Charterer of LNG
from Angola LNG for transportation on the Vessel and the sale of the regasified LNG transported on the Vessel pursuant to the Gas Sales and Purchase Agreements and the purchase of feed gas by Angola LNG from the Gas Suppliers under the Gas Supply
Agreements. 
 “Angolanization Agreement” means the Angolanization Agreement dated 18 December 2007
between the Borrower and the Time Charterer. 
 “Arrangement Fee Letter” means the fee letter in respect of the
fee referred to in clause 7.1 and made between the Borrower and the Agent. 
 “Assignment” means the deed of
assignment of Insurances, Earnings and Requisition Compensation in respect of the Vessel as referred to in clause 8.1.3. 

“Authorisation” means an authorisation, consent, approval, resolution, licence, exemption, filing, notarisation or
registration. 
 “Authorised Investments” means deposits and/or investments with the Account Bank with varying
minimum amounts and periods applying for each case and subject to the prior written approval from the Account Bank. 

“Availability Period” means the period from and including the Execution Date to and including the Availability
Termination Date. 
 “Availability Termination Date” means, the earlier of (a) the date falling 290 days
after the Scheduled Delivery Date of the Vessel, (b) the date falling thirty (30) days after the Delivery Date of the Vessel, (c) the date on which the Time Charterer gives written consent to the Borrower permitting the Borrower to
cancel the Building Contract in accordance with its terms and (d) the date on which the Total Commitments are reduced to zero pursuant to any term of this Agreement, or such other date as may be agreed in writing by the Agent acting on the
instructions of all Lenders and KEIC. 
 “Borrower Priority Payments” means (a) any duly evidenced
payments made pursuant to the Insurances in respect of repairs to the Vessel paid for by the Sponsors on behalf of the Borrower (to the extent it is permitted to do so pursuant to clause 9.5) prior to the receipt of such Insurance proceeds and
(b) any duly evidenced payments received by the Borrower from the Time Charterer which reimburse the Borrower for the costs incurred by the Sponsors on behalf of the Borrower in relation to modifications to the Vessel which have been requested
by the Time Charterer pursuant to the Time Charter and which are reimbursed by the Time Charterer in a lump-sum manner and not through an adjustment to the payment of charterhire under the Time Charter. 

  
 3 

 “Borrower Shareholders” means at any time from and including the Delivery
Date means, Mitsui, NYK LNG and Teekay or in any case, any other person who has become a Borrower Shareholder in place of any of them as permitted by and pursuant to clause 9.2.17 and “Borrower Shareholder” means any one of them.

 “Break Costs” means the amount (if any) by which: 

 

	 	(a)	the interest which a Lender Finance Party should have received for the period from the date of receipt of all or any part of its participation in the Loan or any Unpaid
Sum to the last day of the current Interest Period in respect of that Loan or Unpaid Sum, had the principal amount or Unpaid Sum received been paid on the last day of that Interest Period; 

exceeds: 
  

	 	(b)	the amount which that Lender Finance Party would be able to obtain by placing an amount equal to the principal amount or Unpaid Sum received by it on deposit with a
leading bank in the London interbank market for a period starting on the Business Day following receipt or recovery and ending on the last day of the current Interest Period. 

and “Break Gains” means the amount (if any) by which the amount in (b) exceeds the amount in (a). 

“Builder” means Samsung Heavy Industries Co., Ltd., a company incorporated in the Republic of Korea with its registered
office at 34th Fl., Samsung Insurance Seocho Tower 1321-15, Seocho-Dong, Seocho-Gu, Seoul, Korea 137-857. 
 “Building
Contract” means the contract dated 18 December 2007 on the terms and subject to the conditions of which the Builder has agreed to construct the Vessel for, and deliver the Vessel to the Borrower. 

“Building Contract Assignment Consent and Acknowledgement” means in relation to the Building Contract, the
acknowledgement of notice of and consent to, the assignment of the Building Contract to be given by the Builder in the form scheduled to the Deed of Assignment of Building Contract and Refund Guarantee. 

“Business Day” means a day (other than a Saturday or Sunday) on which banks are open for business in London, Paris,
Seoul, Tokyo and New York. 
 “Buyer Credit” means the aggregate amount of all the Buyer Credit Commitments
advanced or to be advanced by the Lenders to the Borrower under clause 2 or, where the context requires, the aggregate amounts advanced and for the time being outstanding. 
 “Buyer Credit Commitments” means the aggregate of the Commitments of the Lenders for the Vessel as shown in the column headed “Buyer Credit” in Schedule 1, Part 1 as the
same is reduced by the relevant clauses of this Agreement and which shall at no time exceed the Buyer Credit Maximum Amount. 

“Buyer Credit Margin” means zero point seven eight per cent (0.78%) per annum. 

“Buyer Credit Maximum Amount” means the lesser of (a) forty four per cent. (44%) of eighty per cent.
(80%) of the Total Project Cost and (b) ninety two million four hundred thousand Dollars ($92,400,000). 

“Calyon” means Calyon, a credit institution established under the laws of France, acting through its office at 9 quai du
Président Paul Doumer, 92920 Paris, La Défense Cédex, France. 
 “Change of Control” means
either (i) in respect of the Borrower that the Borrower Shareholders either together or any one or more of them shall cease, for any reason whatsoever, to own or control directly or indirectly, sixty-six per cent. (66%) of the shares of
the Borrower or, (ii) in respect of Teekay LNG that as from Delivery and provided that Teekay has transferred its shares in the Borrower to Teekay LNG, Teekay ceases to hold, directly or indirectly at least fifty-one per cent. (51%) of the
voting power from time to time in Teekay GP LLC, the general partner in Teekay LNG. 

  
 4 

 “Classification” means the classification referred to in and as required
by, clause 9.6.3(b). 
 “Classification Society” means the American Bureau of Shipping or such other
classification society which is a member of the International Association of Classification Societies and which the Agent shall at the Borrower’s request have agreed in writing shall be treated as the Classification Society for the Vessel for
the purpose of the Security Documents. 
 “Commercial Facility” means, the credit facility made available by
the Lenders to the Borrower pursuant to this Agreement and more particularly described in clause 2.1.2. 
 “Commercial
Loan” means the aggregate amount advanced or to be advanced by the Lenders to the Borrower under clause 2 or, where the context requires, the aggregate amounts advanced and for the time being outstanding. 

“Commercial Loan Maximum Amount” means the lesser of (a) fifty six per cent. (56%) of eighty per cent.
(80%) of the Total Project Cost and (b) one hundred and seventeen million six hundred thousand Dollars ($117,600,000). 
 “Commercial Loan Margin” means (i) during the Pre-Delivery Period one point zero zero per cent. (1.00%) per annum and (ii) during the Post-Delivery Period one point three
zero per cent. (1.30%) per annum. 
 “Commitment” means, in relation to a Lender, the amount of the Loan
which that Lender agrees under clause 2.1 to advance to the Borrower as its several liability as indicated against the name of that Lender in Schedule 1 Part I and/or Schedule 1 Part II as reduced by any relevant term of this Agreement and
“Commitments” means all or more than one of them. 
 “Commitment Fee” means the commitment fee
to be paid by the Borrower to the Agent on behalf of the Lenders pursuant to clause 7.2. 
 “Communication”
means any notice, approval, demand, request or other communication from one party to this Agreement to any other party to this Agreement. 
 “Company” means at any given time the company responsible for the Vessel’s compliance with (i) the ISM Code under paragraph 1.1.2 of the ISM Code and/or (ii) the ISPS Code
(as the case may be). 
 “Compliance Certificate” means a certificate in the form set out in Schedule 8.

 “Compulsory Acquisition” means requisition for title or other compulsory acquisition, requisition,
appropriation, expropriation, deprivation, forfeiture or confiscation for any reason of the Vessel by any Government Entity or other competent authority, whether de jure or de facto but shall exclude requisition for use or hire not involving
requisition for title. 
 “Contract Instalment Advance” means subject always to the provisions of this
Agreement, Drawings in the maximum amount not exceeding the relevant instalment amount of the Contract Price set out in each column (3) of
Part A of Schedule 7 (as such sumsinstalment amount may be adjusted as permitted under the Building
Contract) which shall be applied in payment of part of the instalment of the Contract Price payable by the Borrower at the completion of the relevant stage of construction of the Vessel pursuant to the Building Contract. 

“Contract Price” means the actual amount payable for the Vessel pursuant to the Building Contract. 

“Corporate Management Agreement” means the Corporate Management and Services Agreement executed or (as the context may
require) to be executed between the Borrower and Mitsui. 

  
 5 

 “Credit Support Document” means any document described as such in the Swap
Agreements and where the context permits, any other document referred to in any Credit Support Document which has the effect of creating an Encumbrance in favour of any of the Lender Finance Parties. 

“Currency of Account” means, in relation to any payment to be made to a Lender Finance Party pursuant to any of the
Security Documents, the currency in which that payment is required to be made by the terms of the relevant Security Document. 

“Debt Service Amount” means in relation to any period all interest, principal and fees payable by the Borrower during
that period under or pursuant to this Agreement, the Swap Agreements and any transactions under the Swap Agreements less any amounts receivable by the Borrower during that period under or pursuant to the Swap Agreements. 

“Debt Service Reserve Account” means the account numbered 09618 078602 004 63 USD and designated the “Debt Service
Reserve Account” in respect of the Vessel, held in the name of the Borrower with the Account Bank and includes each sub-account thereof or time deposit account constituted by moneys originally held on the Debt Service Reserve Account and any
other account of the Borrower with the Account Bank designated by the Agent to be the Debt Service Reserve Account for the purposes of this Agreement, in each case pledged in favour of the Security Trustee. 

“Deed of Assignment of Building Contract and Refund Guarantee” means the deed of assignment referred to in clause 8.1.1.

 “Deed of Assignment of Contracts” means the deed of assignment referred to in clause 8.1.5. 

 “Deed of Covenants” means the deed of covenants referred to in clause 8.1.2. 

“Default Rate” means the rate which is the aggregate of LIBOR, any Mandatory Cost, the Margin and one point zero zero
per cent. (1.00%) per annum. 
 “Delivery Date” means the date on which the Vessel is actually delivered
by the Builder to the Borrower under the Building Contract and accepted by the Time Charterer under the Time Charter. 

“Delivery Date Advance” means a Drawing made, or to be made to finance the instalment of the Contract Price falling due
on the Delivery Date. 
 “Depot Spare Parts” has the meaning given to that term in the Depot Spares Sharing
Agreement. 
 “Depot Spares Sharing Agreement” means the agreement between, amongst others, the Borrower and
the Time Charterer in respect of spare parts for, inter alia, the Vessel. 
 “Distribution Account” means the
account numbered 09618 078602 006 57 USD and designated the “Distribution Account” in respect of the Vessel, held in the name of the Borrower with the Account Bank. 
 “Dividend Lock-up Account” means the account numbered 09618 078602 005 60 USD and designated the “Dividend Lock-up Account” in respect of the Vessel, held in the name of the
Borrower with the Account Bank and includes each sub-account thereof or time deposit account constituted by moneys originally held on the Dividend Lock-up Account and any other account of the Borrower with the Account Bank designated by the Agent to
be the Dividend Lock-up Account for the purposes of this Agreement, in each case pledged in favour of the Security Trustee. 

“Dividend Restriction Event” means the occurrence of one or more of the following events: 

 

	 	(a)	the Agent has not received payment in full of the first Repayment Instalment under the Buyer Credit when due; 

  
 6 

	 	(b)	an Event of Default or a Potential Event of Default has occurred and is continuing unremedied or unwaived which has a Material Adverse Effect; 

 

	 	(c)	any charterhire under the Time Charter has not been paid when due and such charterhire together with interest thereon remains unpaid;

  

	 	(d)	the Borrower has failed to demonstrate that the average DSCR for the then immediately preceding four (4) quarters is lower than 1.13x; 

 

	 	(e)	any of the Accounts (excluding the Distribution Account) is not fully funded to the amount required at that time as required pursuant to clause 8 (provided that this
shall not apply to the Debt Service Reserve Account to the extent that the Borrower’s obligation to retain the DSRA Amount in the Debt Service Reserve Account is satisfied by means of the DSRA Letter of Credit and provided further that this
shall not apply to the Dry Docking Reserve Account to the extent that, for the then applicable period, amounts have been deposited into the Dry Docking Reserve Account in accordance with clause 8.3.2); 

 

	 	(f)	a Total Loss has occurred, unless the Borrower has complied with its prepayment obligations under clause 5.5; or 

 

	 	(g)	the credit rating of an L/C Issuer falls below the Minimum Credit Rating applicable to it as described in clause
9.1.20.9.1.20 where (i) a demand has been made under the DSRA Letter of Credit in accordance with clause 8.5 and (ii) the L/C Issuer has failed to pay the full
amount so demanded. 

 “Documentation Agency Fee Letter” means the fee letter in respect of
the fee referred to in clause 7.4 and made between the Borrower and Calyon. 
 “Dollars” “US$” and
“$” each means available and freely transferable and convertible funds in lawful currency of the United States of America. 
 “Dollar Equivalent” of an amount in a currency other than Dollars for any day means the amount of Dollars required to purchase that amount at the spot rate of exchange of the Agent for
the purchase of the applicable currency with Dollars in the London foreign exchange market at 11.00 a.m. for delivery on that day. 
 “Drawdown Date” means the date on which a Drawing is advanced. 

“Drawdown Notice” means a notice substantially in the form set out in the relevant part of Schedule 5. 

“Drawing” means each borrowing of a proportion of the Commitment by the Borrower pursuant to clause 2 whether as
a Contract Instalment Advance and/or an Ancillary Cost Advance and/or the Delivery Date Advance or (as the context may require) the principal amount of such borrowing. 
 “Dry Docking Reserve Account” means the account numbered 09618 078602 002 69 USD and designated the “Dry Docking Reserve Account” in respect of the Vessel, held in the name of
the Borrower with the Account Bank and includes each sub-account thereof or time deposit account constituted by moneys originally held on the Dry Docking Reserve Account and any other account of the Borrower with the Account Bank designated by the
Agent to be the Dry Docking Reserve Account for the purposes of this Agreement, in each case pledged in favour of the Security Trustee. 
 “Dry Docking Reserve Account Payments” means the sum calculated by the Borrower which should be reserved in order to meet the costs in respect of the next scheduled dry docking of the
Vessel (including, without limitation, the costs in respect of the long term maintenance and repair of the Vessel), each such calculation shall be demonstrated as being fair and reasonable to the Agent’s satisfaction not later than the date
falling, in respect of the first scheduled dry docking date, three (3) Months prior to the Scheduled Delivery Date and, in respect of each subsequent scheduled dry docking date, not later than the date falling three (3) Months prior to the
immediately preceding scheduled dry docking date of the Vessel. 

  
 7 

 “DSCR” means in relation to any period the ratio which the
Revenues less Operating Costs during that period bear to the Debt Service Amount paid or payable in relation to that period. 

“DSRA Amount” has the meaning given to that term in clause 9.1.18. 

“DSRA Letter of Credit” means an irrevocable letter of credit in a form and substance acceptable in all respects to the
Agent which, if issued, shall be issued by an L/C Issuer for an original amount determined by the Agent to be equal whether alone or in aggregate to 6 Months principal and interest repayments under this Agreement or such other amounts as referred to
in clause 9.1.18 and for a period of not less than 1 year or, during the final year before the Maturity Date, such other period of less than 1 year with the prior written consent of the Agent. 

“Earnings” means all hires including (without limitation) all time charter hire and bareboat charter hire, freights,
pool income and other sums payable to or for the account of the Borrower in respect of the Vessel including (without limitation) all remuneration for salvage and towage services, demurrage and detention moneys, contributions in general average,
compensation in respect of any requisition for hire and damages and other payments (whether awarded by any court or arbitral tribunal or by agreement or otherwise) for breach, termination or variation of any contract for the operation, employment or
use of the Vessel. 
 “Encumbrance” means any mortgage, charge (whether fixed or floating), pledge, lien,
assignment, hypothecation, preferential right, option, title retention or trust arrangement or any other agreement or arrangement which, in any of the aforementioned instances, has the effect of creating security. 

“Environmental Affiliate” means an agent or employee of the Borrower or a person in a contractual relationship with the
Borrower or any sub-lessee in respect of the operation, management or maintenance of the Vessel (including without limitation, the operation of or the carriage of cargo of the Vessel). 

“Environmental Approval” means any permit, licence, ruling, variance, exemption, certificate, filing, comment,
Authorisation or other approval, required at any time under any applicable Environmental Law. 
 “Environmental
Claim” means any claim by any person which arises out of or in connection with an Environmental Incident or any alleged Environmental Incident or any breach of, or non-compliance with, or otherwise relates to any Environmental Law or
Environmental Approval. 
 “Environmental Incident” means: 

 

	 	(a)	any release, discharge or emission of Environmentally Sensitive Material from the Vessel; or 

 

	 	(b)	any incident in which Environmentally Sensitive Material is released, discharged or emitted from a vessel other than the Vessel and which involves a collision between
the Vessel and such other vessel or some other incident of navigation or operation, in either case, in connection with which the Vessel is actually and/or is reasonably likely to be arrested, attached, detained or injuncted and/or where the
Borrower, or any Environmental Affiliate or any of their respective officers, employees or other persons retained or instructed by them are finally determined to be at fault or allegedly at fault or otherwise liable to any legal or administrative
action; or 

  

	 	(c)	any other incident in which Environmentally Sensitive Material is released otherwise than from the Vessel and in connection with which the Vessel is actually or is
reasonably likely to be arrested, attached, detained or injuncted and/or where the Borrower or any Environmental Affiliate or any of their respective officers, employees or other persons retained or instructed by them are finally determined to be at
fault or allegedly at fault or otherwise liable to any legal or administrative action. 

  
 8 

 “Environmental Law” means any or all laws applicable or relating to
pollution or contamination or protection of the environment, to the generation, manufacture, processing, distribution, use or misuse, treatment, storage, disposal, carriage or holding of Environmentally Sensitive Material or to actual or threatened
emissions, releases, spillages or discharges of Environmentally Sensitive Material. 
 “Environmentally Sensitive
Material” means liquefied natural gas, oil, oil products and any other element or substance whether natural or artificial and whether consisting of gas, liquid, solid or vapour (including any chemical, gas or other hazardous or noxious
substance) which is or is capable of becoming polluting, toxic, hazardous, harmful or damaging to mankind or the environment or any living organism. 
 “Event of Default” means any of the events set out in clause 10.2. 
 “Execution Date” means the date on which this Agreement is executed by each of the parties hereto. 
 “Facility Period” means the period beginning on the Execution Date and ending on the date when the whole of the Loan Outstandings and all other amounts due and owing under this Agreement
have been repaid in full and the Borrower has ceased to be under any further actual liability to the Lender Finance Parties under or in connection with the Security Documents. 
 “Fee Letters” means the Arrangement Fee Letter, the Agency Fee Letter, the Documentation Agency Fee Letter and the Account Bank Fee Letter. 

“Financial Indebtedness” means, in relation to a person (the “debtor”), a liability of the
debtor: 
  

	 	(a)	for principal, interest or any other sum payable in respect of any moneys borrowed or raised by the debtor; 

 

	 	(b)	under any loan stock, bond, note or other security issued by the debtor; 

  

	 	(c)	under any acceptance credit, guarantee or letter of credit facility issued for the account of the debtor; 

 

	 	(d)	under a lease or any other agreement having the commercial effect of a borrowing or raising of money by the debtor; 

 

	 	(e)	under any foreign exchange transaction, any interest or currency swap or any other kind of derivative transaction entered into by the debtor or, if the agreement under
which any such transaction is entered into requires netting of mutual liabilities, the liability of the debtor for the net amount; or 

  

	 	(f)	under a guarantee, indemnity or similar obligation entered into by the debtor in respect of a liability of another person which would fall within paragraphs (a) to
(e) if the references to the debtor referred to the other person, 

 provided that, Financial Indebtedness
shall exclude (a) any shareholder loans and/or other debt instruments of the Borrower to the Borrower Shareholders which are fully subordinated to the Loan in accordance with clause 2.1.1 of the Letter of Sponsors Undertaking and (b) any
shareholder loans which are repaid pursuant to clause 2.3.4. 
 “Flag State” means the Bahamas. 

“GAAP” means, with respect to a person, the generally accepted accounting principles consistently applied by such person
in preparation of its financial statements. 

  
 9 

 “Gas Sales and Purchase Agreements” means the agreements entered into or
(as the context may require) to be entered into between the Time Charterer and one or more affiliates of the Gas Suppliers for the sale and purchase of the LNG transported on the Vessel to the Gulf LNG Clean Energy regasification terminal located at
the Port of Pascagoula, Mississippi. 
 “Gas Suppliers” means the suppliers of feed gas to Angola LNG pursuant
to the Gas Supply Agreements. 
 “Gas Supply Agreements” means the gas supply agreements entered into or (as
the context may require) to be entered into between each of the Gas Suppliers and Angola LNG for the supply by the Gas Suppliers of feed gas to Angola LNG for the purpose of liquefaction at the Angola LNG liquefaction plant and the subsequent sale
of LNG by Angola LNG to the Time Charterer pursuant to the LNG Sale and Purchase Agreement. 
 “Government Entity”
means and includes (whether having a distinct legal personality or not) any national or local government authority, board, commission, department, division, organ, instrumentality, court or agency. 

“Guarantee Bond” has the meaning given to that term in the
Building Contract. 
 “Holding Company” means, in relation to any entity (the “first
entity”), any other entity in respect of which the first entity is a Subsidiary. 
 “Indebtedness”
has the meaning given to that term in the Intercreditor Deed. 
 “Insurances” means all policies and
contracts of insurance (including but not limited to hull and machinery, all entries in protection and indemnity or war risks associations) which are from time to time taken out or entered into in respect of or in connection with the Vessel or her
increased value and her Earnings and (where the context permits) all benefits thereof, including all claims of any nature and returns of premium. 
 “Insured Loss Value” means, at any relevant time, 110% of the aggregate from time to time of the Lender Indebtedness. 

“Intercreditor Deed” means an intercreditor deed to be entered into between (1) the Agent, (2) the Security
Trustee, (3) the Borrower, (4) the Lenders, (5) the KEIC Agent and (6) the Swap Providers. 

“Interest Payment Date” means each date for the payment of interest in accordance with clause 6. 

“Interest Period” means each interest period selected pursuant to clause 6. 

“ISM Code” means the International Safety Management Code (including the guidelines on its implementation) adopted by
the International Maritime Organisation Assembly as Resolutions A. 741(18) and A. 788(19) and incorporated into SOLAS as the same may be amended or supplemented from time to time and all further resolutions, circulars, codes, guidelines, regulations
and recommendations which are now or may in the future be issued by or on behalf of the International Maritime Organisation or any other entity with responsibility for implementing the ISM Code. 

“ISSC” means a valid international ship security certificate for a Vessel issued under the ISPS Code. 

“ISPS Code” means the International Vessel and Port Facility Security Code adopted by the International Maritime
Organisation Assembly as the same may have been or may be amended or supplemented from time to time. 
 “KEIC”
means Korea Export Insurance Corporation of 2-16 Floors, Seoul Central Building, 136 Seorin Dong, Jongro-ku, Seoul 110-729, Korea. 

  
 10 

 “KEIC Acceptance Letter” means the letter or letters to be entered into
from KEIC to, amongst others, the KEIC Agent. 
 “KEIC Buyer Credit Policy” means the Medium and Long Term
Export Insurance Policy, the General Terms and Conditions of Medium and Long Term Export Insurance (Buyer’s Credit, Standard Type) and the special policy attached thereto to be issued by KEIC in respect of 95% of the Buyer Credit in relation to
political and commercial risks. 
 “KEIC Insurance Premium” means
Fourfour point Fivefive per cent. (4.5%) of the Buyer Credit Maximum Amount.

 “law” or “Law” means any law, statute, treaty, convention, regulation,
instrument or other subordinate legislation or other legislative or quasi-legislative rule or measure, or any order or decree of any government, judicial or public or other body or authority, or any directive, code of practice, circular, guidance
note or other direction issued by any competent authority or agency (whether or not having the force of law). 
 “L/C
Issuer” means a financial institution issuing the DSRA Letter of Credit and having a Minimum Credit Rating. 

“Lender Finance Parties” means the Lenders, the Agent, the Security Trustee, the KEIC Agent and the Swap Providers.

 “Lender Indebtedness” means the Buyer Credit Liabilities and the Commercial Liabilities (each as defined in
the Intercreditor Deed). 
 “Letter of Sponsors Undertaking” means the undertaking referred to in clause 8.1.7
and executed or (as the context may require) to be executed by each of the Sponsors on a several basis in favour of the Security Trustee in form and substance acceptable to the Lenders. 

“Leverage Ratio” means the ratio of the Loan Outstandings to the aggregate of (without duplication) the Minimum Borrower
Shareholders’ Equity, the Additional Shareholders’ Equity (to the extent the same has been advanced) and the issued share capital of the Borrower, shareholder loans and/or other debt instruments of the Borrower to the Borrower Shareholders
and the amounts standing to the credit of its capital and revenue reserves (including any share premium account or capital redemption reserve but excluding any re-evaluation reserve). 

“LIBOR” means, in relation to a particular period: 

 

	 	(a)	the offered rate for deposits of Dollars for a period equal to such period and in an amount approximately equal to the amount in relation to which LIBOR is to be
determined at 11.00 a.m. (London time) two (2) London Business Days prior to the first day of such period as displayed on Reuters Page LIBOR 01 on the Reuters Monitor Money Rates (the “Screen Rate”) Service or such other
page as may replace such page on such system or on any other system for the time being displaying the rate so designated and if no such rate is available for any such period the rate shall be determined by interpolating between rates for such
periods as are so available; or 

  

	 	(b)	if no Screen Rate is available for Dollars for any Interest Period, LIBOR for such period shall be the arithmetic mean (rounded upwards if necessary to five decimal
places) of the rates respectively quoted to the Agent or any successor entity thereto by each of the Reference Banks (or, if not all the Reference Banks provide a quotation when requested, the arithmetic mean of the rates which are quoted) as such
Reference Banks’ offered rates for deposits of Dollars in an amount approximately equal to the amount in relation to which LIBOR is to be determined for a period equivalent to such period to prime banks in the London Interbank Market at 11.00
a.m. (London time) two (2) London Business Days prior to the first day of such period; or 

  

	 	(c)	if on such date no such rate can be ascertained pursuant to paragraph (a) or (b) of this definition, LIBOR for such period shall be the rate, determined by
the Agent at which the Agent or any successor entity thereto is able to obtain deposits of Dollars in an amount approximately equal to the amount in respect of which LIBOR is to be determined, from whatever source it may select for a period
equivalent to such period at 11.00 a.m. (London time) two (2) London Business Days prior to the first day of such period. 

  
 11 

 “LNG” means liquefied natural gas. 

“LNG Agreement” means the LNG Sales and Purchase Agreement entered or (as the context may require) to be entered into
between Angola LNG and the Time Charterer pursuant to which Angola LNG will supply to the Time Charterer and the Time Charterer will purchase from Angola LNG, LNG for transportation on the Vessel from the Angola LNG liquefaction plant to the Gulf
LNG Clean Energy regasification terminal located at the Port of Pascagoula, Mississippi. 
 “Loan” means the
aggregate amount advanced or to be advanced by the Lenders to the Borrower under clause 2 or, where the context requires, the aggregate amounts advanced and for the time being outstanding. 

“Loan Outstandings” at any time means the total of all Drawings made at that time, to the extent not reduced by
repayments, prepayments and voluntary reductions. 
 “London Business Days” means a day (other than a Saturday
or Sunday) on which banks are open for business in London. 
 “Majority Lenders” means a Lender or Lenders
whose Commitments in respect of the Loan aggregate more than sixty six point six seven per cent (66.67%) of the aggregate of all the Commitments in respect of the Loan. 
 “Manager” means Teekay Shipping Ltd. or one of its Affiliates/NYK LNG, or another management company approved by the Agent (acting under the instructions of the Majority
Lenders and KEIC). 
 “Management Agreement” means, in respect of the Vessel, the management agreement, to be
in form and substance acceptable to the Lenders acting reasonably, entered into, or as the case may be, to be entered into between the Borrower and the Manager providing for the Manager to manage the Vessel. 

“Management Agreement Consent and Acknowledgement” means the acknowledgement of notice and consent to be given by the
Manager in respect of the Management Agreement in the form scheduled to the Deed of Assignment of Contracts. 

“Manager’s Undertaking” means an undertaking referred to in clause 8.1.8 executed or (as the context may require)
to be executed by the Manager in favour of the Security Trustee as a condition precedent to the approval of the Management Agreement, such undertakings to be in a form and substance satisfactory to the Lenders in all respects. 

“Mandatory Cost” means for each Lender to which it applies, the cost imputed to that Lender of compliance with the
mandatory liquid asset requirements of the Bank of England and/or the banking supervision or other costs imposed by the Financial Services Authority or the European Central Bank, determined in accordance with Schedule 6 (Calculation of the
Mandatory Cost). 
 “Mandatory Prepayment Event” means any of the events set out in clauses 5.5,
5.6, 5.7, 5.8 or 5.9. 
 “Margin” means the Buyer Credit Margin or the Commercial Loan Margin as applicable.

 “Master” means the master of the Vessel from time to time. 

“Material Adverse Effect” means a material adverse effect on (a) the Borrower’s financial or operating
condition or (b) the Borrower’s or any other Security Party’s ability to comply with its material obligations under any of the Security Documents or (c) the validity or enforceability of any of the Security Documents or
(d) the rights and remedies of the Lender Finance Parties under the Security Documents. 

  
 12 

 “Maturity Date” means the date falling twelve (12) years after the
Delivery Date of the Vessel.  
 “Maximum Loan Amount” means two hundred and ten million Dollars
($210,000,000). 
 “Minimum Credit Rating” means (a) in relation to any L/C Issuer either a minimum
Standard and Poors corporate rating of AA- or a minimum Moodys long term credit rating of Aa3 and (b) in relation to the Refund Guarantor a minimum long term credit rating of A- or equivalent by either Standard and Poors or Fitch. 

“Minimum Borrower Shareholders’ Equity” means subject always to the provisions of the Letter of Sponsors
Undertaking, a sum equal to no less than the lesser of 20% of the Scheduled Vessel Project Cost (being $52,500,000) and 20% of the Total Project Cost, made or (as the context may require) to be made available to the Borrower whether directly or
indirectly by way of contributions to the ordinary, preferential or other class of share capital of the Borrower or by way of shareholder loans and/or debt instruments of the Borrower which shareholder loans and/or debt instruments shall be
subordinated in all respects to the amounts due or owing to the Agent, the Security Trustee, the KEIC Agent, the Swap Providers or the Lenders under the Security Documents on terms acceptable to them, to be applied on a pro-rata basis with the
Drawings in respect of the costs to be funded by the Loan. 
 “Mitsui” means Mitsui & Co., Ltd. a
Japanese corporation with its registered office at 2-1, Ohtemachi 1-chome, Chiyoda-ku, Tokyo, 100-0004, Japan. 

“Moodys” means Moodys’ Investors Service of 99 Church Street, New York, NY 10007, USA and includes its successors
in title. 
 “Month” means a period starting on one day in a calendar month and ending on the numerically
corresponding day in the next calendar month, except that: 
  

	 	(a)	if the numerically corresponding day is not a Business Day, that period shall end on the next Business Day in that calendar month in which that period is to end if
there is one, or if there is not, on the immediately preceding Business Day; and 

  

	 	(b)	if there is no numerically corresponding day in the calendar month in which that period is to end, that period shall end on the last Business Day in that calendar
month. 

 The above rules will only apply to the last Month of any period, and “Monthly” shall be
construed accordingly. 
 “Mortgage” means together the first priority statutory ship mortgage together with
the Deed of Covenants collateral thereto over the Vessel made or to be made between the Borrower and the Security Trustee referred to in clause 8.1.2 (the “Mortgage”). 

“NYK” means Nippon Yusen Kabushiki Kaisha, a Japanese corporation with its registered office at 3-2, Marunouchi 2-chome,
Chiyoda-ku, Tokyo, 100-0005, Japan. 
 “NYK LNG” means NYK LNG (Atlantic) Ltd., a company incorporated in
England and Wales with its registered office at Citypoint, 1 Ropemaker Street, London EC2Y 9NY. 
 “Operating
Costs” means in relation to any period, the Borrower’s operating costs in respect of the Vessel, but excluding any unanticipated costs of a non-recurring and extraordinary nature which have not been reimbursed but which are to be
reimbursed to the Borrower (and in respect of which the Borrower shall provide such evidence as the Agent may require) and no amount in respect of which is included in the Revenues for such period. 

  
 13 

 “Operator” means any person concerned in the operation of the Vessel and
falling within the definitions of “Company” set out in the ISM Code. 
 “Permitted Encumbrance”
means: 
  

	 	(a)	Encumbrances created or contemplated by this Agreement or any of the Relevant Documents; 

 

	 	(b)	liens for unpaid crew’s wages; 

  

	 	(c)	liens for salvage; 

  

	 	(d)	liens arising by operation of law for not more than 2 Months’ prepaid hire under any charter in relation to a Vessel not prohibited by the Relevant Documents;

  

	 	(e)	liens for Master’s disbursements incurred in the ordinary course of trading; 

 

	 	(f)	other liens arising by operation of law or otherwise in the ordinary course of the operation, repair or maintenance of the Vessel and which secure amounts not exceeding
the Threshold Amount where the Borrower is contesting the claim giving rise to such lien in good faith by appropriate steps and for the payment of which adequate reserves have been made in case the Borrower finally has to pay such claim so long as
any such proceedings shall not, and may reasonably be considered unlikely to lead to the arrest, sale, forfeiture or loss of the Vessel, or any interest in the Vessel; 

 

	 	(g)	any security interest created over the Depot Spare Parts by a sister vessel in favour of its lenders; 

 

	 	(h)	any security interest created in favour of a claimant or defendant in any action of the court or tribunal before whom such action is brought as security for costs and
expenses where the Borrower is prosecuting or defending such action in good faith by appropriate steps or which are subject to a pending appeal and for which there shall have been granted a stay of execution pending such appeal and for the payment
of which adequate reserves have been made so long as any such proceedings or the continued existence of such security interest shall not and may reasonably be considered unlikely to lead to the arrest, sale, forfeiture or loss of, the Vessel or any
interest in the Vessel; and 

  

	 	(i)	security interests arising by operation of law in respect of taxes which are not overdue for payment or taxes which are overdue for payment but which are being
contested in good faith by appropriate steps and in respect of which appropriate reserves have been made so long as any such proceedings or the continued existence of such security interest shall not and may reasonably be considered unlikely to lead
to the arrest, sale, forfeiture or loss of a Vessel, or any interest in the Vessel. 

 “Post-Delivery
Period” means the period from and including the date falling immediately after the Delivery Date up to and including the last day of the Facility Period. 
 “Potential Event of Default” means any event which, with the giving of notice and/or the passage of time and/or the satisfaction of any materiality test, would constitute an Event of
Default. 
 “Pre-Delivery Period” means the period from and including the Execution Date up to and including
the Delivery Date. 
 “Project Co-ordination Agreement” means the project co-ordination agreement entered or,
as the case may be, to be entered into between the Borrower, the Time Charterer and the Security Trustee to be in form and substance satisfactory to all Lenders. 
 “Project Documents” means the Building Contract, the Refund Guarantee, the Management Agreement, the Corporate Management Agreement, the Supervision Agreement, the Tripartite Agreement,
the Depot Spares Sharing Agreement and the Time Charter and any other agreements or documents which the Agent and the Borrower agree shall be a “Project Document”. 

  
 14 

 “Proportionate Share” in respect of a Loan means, for each Lender, the
percentage that its Commitment relating to that Loan bears to the aggregate Commitments of all Lenders for that Loan from time to time, being initially the percentage indicated against the name of that Lender in Schedule 1. 

“Protocol of Delivery and Acceptance” has the meaning given to that term in the Building Contract. 

“Qualifying Entity” means a person having a long term corporate credit rating of at least BBB-with Standard and Poors or
Baa3 with Moodys; 
 “Reference Banks” means, in relation to LIBOR, the principal London offices of the Agent,
HSBC Bank plc, The Royal Bank of Scotland plc and Barclays Bank plc and such other banks as may be appointed by the Agent in consultation with the Borrower. 
 “Refund Guarantee” means the refund guarantee dated 20 December 2007 and issued by the Refund Guarantor in favour of the Borrower. 

“Refund Guarantee Consent and Acknowledgement” means the acknowledgement of notice of and consent to, the assignment in
respect of the Refund Guarantee to be given by the Refund Guarantor in the form scheduled to the Deed of Assignment of Building Contract and Refund Guarantee. 
 “Refund Guarantor” means ABN AMRO a bank established and existing under the laws of the Netherlands and acting through its offices at 6/F, Seoul Finance Centre 84, Taepyeongno 1-ga,
Jung-gu, Seoul 100-768, Korea CPO Box 3035, Seoul. 
 “Relevant Documents” means the Security Documents, the
Project Documents and the KEIC Buyer Credit Policy. 
 “Relevant Jurisdiction” means any jurisdiction in which
or where any Security Party is incorporated, resident, domiciled, has a permanent establishment, carries on, or has a place of business or is otherwise effectively connected. 
 “Repayment Date” means any date for payment of a Repayment Instalment in accordance with clause 5. 
 “Repayment Instalment” means any instalment of a Loan to be repaid by the Borrower in accordance with clause 5. 
 “Requisition Compensation” means all compensation or other money which may from time to time be payable to the Borrower as a result of the Compulsory Acquisition of the Vessel.

 “Retention Account” means the account numbered 09618 078602 003 66 USD and designated the “Retention
Account” in respect of the Vessel, held in the name of the borrower with the Account Bank and includes each sub-account thereof or time deposit account constituted by moneys originally held on the Retention Account and/or any other account of
the Borrower, with the Account Bank designated by the Agent to be the Retention Account for the purposes of this Agreement, in each case pledged in favour of the Security Trustee. 

“Retention Amount” means, in relation to any Retention Date, such sum as shall be the aggregate of: 

 

	 	(a)	 one-third
(1/
3) of the Repayment Instalment falling due for payment pursuant to clause 5.1 (as the same may have been reduced
by any permitted or required prepayment) on the next Repayment Date after the relevant Retention Date other than in the case of the final Repayment Instalment in respect of which no retention shall be made; and 

 

	 	(b)	 one-third
(1/
3) of the aggregate amount of interest falling due for payment in respect of the Loan during and at the end of
each Interest Period current at the relevant Retention Date as reduced or, as the case may be, increased by the amounts (if any) to be paid or, as the case may be, to be received by the Borrower under the Swap Agreements.

  
 15 

 “Retention Dates” means in relation to the Loan, the date falling one
(1) Month after the Delivery Date and each of the dates falling at Monthly intervals after such date and prior to the final Repayment Date. 
 “Revenue Account” means the account numbered 09618 078602 001 72 USD and designated the “Revenue Account” in respect of the Vessel, held in the name of the Borrower with the
Account Bank and includes each sub-account thereof or time deposit account constituted by moneys originally held on the Revenue Account and/or any other account of the Borrower with the Account Bank designated by the Agent to be the Revenue Account
for the purposes of this Agreement, in each case pledged in favour of the Security Trustee. 
 “Revenues”
means, in relation to any period, all moneys received or receivable by the Borrower in relation to that period including: 
  

	 	(a)	moneys received or receivable pursuant to the Time Charter; 

  

	 	(b)	amounts representing interest on the Accounts; and 

  

	 	(c)	all other amounts received or receivable by the Borrower during the relevant period, but excluding Drawings paid to the Borrower under this Agreement.

 “Revised Delivery Date” means any Revised Delivery Date as defined in Article V(d) of the
Building Contract and pursuant to which the Borrower is entitled to delay delivery of the Vessel by notice in writing to the Builder on two occasions and by up to 45 days on each occasion. 

“Scheduled Delivery Date” means 31 October 2011 or any Revised Delivery Date. 

“Scheduled Vessel Project Cost” means two hundred and sixty two million five hundred thousand Dollars ($262,500,000).

 “Security Documents” means this Agreement, the Swap Agreement, any other Credit Support Documents, the Deed
of Assignment of Building Contract and Refund Guarantee, the Assignment, the Deed of Assignment of Contracts, the Letter of Sponsors Undertaking, the Mortgage, the Deed of Covenants, the Share
PledgesCharges, the Account Charge, the Project Co-ordination Agreement, the Building Contract Assignment Consent and Acknowledgement, the Refund Guarantee Consent and
Acknowledgement, the Supervision Agreement Consent and Acknowledgement, the Management Agreement Consent and Acknowledgement, the Sub Management Agreement Consent and Acknowledgement, the Intercreditor Deed, the Manager’s
Undertaking, the Fee Letters or (where the context permits) any one of them and any other agreement or document which may at any time be executed to guarantee or as security for the payment or repayment of all or any part of the Indebtedness and
which the Borrower and the Agent agree to be a Security Document. 
 “Security Parties” means, at any relevant
time, the Borrower, the Sponsors, the Borrower Shareholders, the Supervisor, the Manager and, with the consent of the Borrower, any other party who may at any time during the Facility Period be liable for, or provide security for, all or any part of
the Lender Indebtedness, and “Security Party” means any one of them. 
 “Security Trustee”
means BNP Paribas S.A. in its capacity as security trustee for the purposes of the Security Documents. 

  
 16 

 “Share
PledgesCharges” means the share pledgescharge over shares from
each Borrower Shareholder in respect of the shares in the Borrower as referred to in clause 8.1.6. 
 “SOLAS”
means International Convention for the Safety of Life at Sea, 1974, with Protocol 1978 and Amendments of 1981, 1983, 1988, 1991, 1992, 1994, 1996, 1998, 2000, 2002, 2003 and 2004 as the same may be further amended or supplemented, consolidated
or replaced from time to time. 
 “Sponsors” means Mitsui, NYK and Teekay, or in any case, any other person who
has acceded to the Security Documents as a Sponsor in place of any of them as permitted by and pursuant to clause 9.2.17 and “Sponsor” means any one of them. 
 “Standard & Poors” means Standard & Poors Rating Services of 25 Broadway, New York, NY 10004, USA and includes its successors in title. 

“Subsidiary” means a subsidiary undertaking, as defined in section 736 Companies Act 1985 or any analogous definition
under any other relevant system of law. 
 “Supervision Agreement” means the supervision agreement to be
entered into between the Borrower and the Supervisors as supervisors in respect of, inter alia, the Vessel. 

“Supervision Agreement Consent and Acknowledgement” means the acknowledgement of notice of and consent to, the
assignment in respect of the Supervision Agreement to be given by the Supervisor in the form scheduled to the Deed of Assignment of Contracts. 
 “Supervisors” means Teekay Shipping Limited and NYK or any one of their respective Affiliates who are parties to the Supervision Agreement and “Supervisors” means either
of them; 
 “Swap Agreement” means each ISDA Master Agreement and each confirmation issued thereunder between a
Swap Provider and the Borrower together with any novation documentation entered into in relation to swap arrangements relating to this Agreement entered into prior to the date hereof (together the “Swap Agreements”). 

“Swap Margin” means the Swap Margin applicable to each Swap Agreement as set out in the Swap Margin Side Letters.

 “Swap Margin Side Letters” means the letter agreement to be entered into between the Swap Providers and the
Borrower setting out the Swap Margin in form and substance satisfactory to each of the Swap Providers and the Borrower. 

“Swap Providers” means each of the Lenders (including, for
the avoidance of doubt, any entity which has ceased to be a Lender pursuant to clause 12) or their respective affiliate acting in its capacity as a swap provider pursuant to a Swap Agreement and “Swap Provider” means any one or
more of them. 
 “Tax” includes all present and future taxes, levies (whether by deduction, withholding or
otherwise), imposts, duties, or charges of a similar nature (or any amount payable on account of or as security for any of the foregoing), including, but not limited to, income tax, corporation tax, VAT, stamp duty, customs and other impost or
export duty or excise duty, imposed by any statutory, governmental, national, international, state or local taxing or fiscal authority, body or agency or department whatsoever or any central bank, monetary agency or European Union institution,
whether in the United Kingdom or elsewhere together with interest thereon and any additions, fines, surcharges, penalties in respect thereof or relating thereto and “Taxes” and “Taxation” shall be construed
accordingly. 
 “Teekay” means Teekay Corporation a company incorporated in the Marshall Islands with its
registered office at c/o Trust Company Complex, Ajeltake Road, Ajeltake Island, Majuro, Marshall Islands MH 96960. 

  
 17 

 “Teekay LNG” means Teekay LNG Partners L.P. a limited partnership formed in
the Marshall Islands with its registered office at c/o Trust Company Complex, Ajeltake Road, Ajeltake Island, Majuro, Marshall islands MH96960. 
 “Teekay Shipping Limited” means Teekay Shipping Limited, a Bermuda company constituted from the Commonwealth of the Bahamas with its registered office at 4th Floor, Belvedere Building, 69
Pitts Bay Road, Hamilton, HM 09, Bermuda. 
 “Threshold Amount” means two million Dollars ($2,000,000) or its
Dollar Equivalent. 
 “Time Charter” means in respect of the Vessel, the time charter dated 18 December
2007 between the Borrower and the Time Charterer. 
 “Time Charterer” has the meaning ascribed to that term in
Recital D above.  
 “Total Loss” means:- 

 

	 	(a)	an actual, constructive or compromised or arranged total loss of the Vessel; or 

 

	 	(b)	any Compulsory Acquisition of the Vessel; or 

  

	 	(c)	the hijacking, theft, condemnation, capture, seizure, arrest, detention or confiscation of the Vessel (other than where the same amounts to the Compulsory Acquisition
of the Vessel) by any person or entity, including any Government Entity, or by persons acting or purporting to act on behalf of any Government Entity, unless the Vessel is released and restored to the Borrower from such hijacking, theft,
condemnation, capture, seizure, arrest, detention or confiscation within thirty (30) days after the occurrence thereof or where such event is an insured risk under the Insurances, six (6) Months or such lesser period as is stipulated in
the relevant Insurances as being required to elapse before a Total Loss of the Vessel shall be deemed as having occurred. 

 “Total Project Cost” means a sum equal to the aggregate amount in Dollars of the Contract Price and Ancillary Costs. 

“Transfer Certificate” means a certificate materially in the form set forth in Schedule 4 or any other form agreed by
the Borrower and the Agent signed by a Lender and a Transferee whereby:- 
  

	 	(a)	such Lender procures the transfer to such Transferee of all or a part of such Lender’s rights and obligations under this Agreement upon and subject to the terms
and conditions set out in clause 12; and 

  

	 	(b)	such Transferee undertakes to perform the obligations it will assume as a result of delivery of such certificate to the Agent as is contemplated in clause 12.

 “Transfer Date” means, in relation to any Transfer Certificate, the date for the making of the
transfer specified in the schedule to such Transfer Certificate. 
 “Tripartite Agreement” means the Tripartite
Agreement dated 18 December 2007 and made between the Builder, the Borrower and the Time Charterer. 
 “Tripartite
Agreement Consent and Acknowledgement” means the acknowledgement of and consent to, the assignment in respect of the Tripartite Agreement to be given by the Builder and the Time Charterer in the form scheduled to the Deed of Assignment of
Contracts. 
 “Transferee” means a bank or other financial institution to which a Lender transfers all or part
of such Lender’s rights and obligations under this Agreement. 
 “Unpaid Sum” means any sum due and
payable but unpaid by a Security Party under the Security Documents. 

  
 18 

 “Value Added Tax” or “VAT” means: 

 

	 	(a)	value added tax of the United Kingdom as provided for in the VATA including legislation (delegated or otherwise) supplementary thereto, and any similar or substituted
tax, or any tax imposed, levied or assessed in the United Kingdom on added value or turnover; and 

  

	 	(b)	any similar tax imposed, levied or assessed in any jurisdiction outside the United Kingdom. 

“VATA” means the Value Added Tax Act 1994. 
 “Vessel” means the Vessel listed in Schedule 2 and everything now or in the future belonging to it on board and ashore. 

“Vessel Registry” means the Bahamas Vessel Registry. 

“Wholly-Owned Subsidiary” has the meaning given to the term “wholly-owned subsidiary” in section 736 of the
Companies Act 1985. 
  

	1.2	Headings 

 clause headings
and table of contents are inserted for convenience of reference only and shall be ignored in the interpretation of this Agreement. 
  

	1.3	Construction of certain terms 

 In this Agreement, unless the context otherwise requires: 
  

	1.3.1 	references to clauses and schedules are to be construed as references to the clauses of, and schedules to, this Agreement and references to this Agreement include its
schedules; 

  

	1.3.2 	references to (or to any specified provision of) this Agreement or any other document shall be construed as references to this Agreement, that provision or that
document as in force for the time being and as amended or supplemented in accordance with the terms thereof, or, as the case may be, with the agreement of the relevant parties; 

 

	1.3.3 	references to a “regulation” include any present or future regulation, rule, directive, requirement, request or guideline (whether or not having the force of
law) of any agency, authority, central bank or government department or any self-regulatory or other national or supra-national authority; 

  

	1.3.4 	words importing the plural shall include the singular and vice versa; 

  

	1.3.5 	references to a time of day are to London time; 

  

	1.3.6 	references to a “person” shall be construed as including references to an individual, firm, company, corporation, unincorporated body of persons or any
Government Entity and includes its successors and permitted transferees and assigns; 

  

	1.3.7 	references to a “guarantee” include references to an indemnity or other assurance against financial loss including, without limitation, an obligation to
purchase assets or services as a consequence of an event of default by any other person to pay any Indebtedness and “guaranteed” shall be construed accordingly; 

 

	1.3.8 	references to any enactment shall be deemed to include references to such enactment as re-enacted, amended or extended; and 

 

	1.3.9 	references to any of the Lender Finance Parties includes its successors and permitted transferees and assigns. 

  
 19 

	1.3.10 	references to “indebtedness” means any obligation for the payment or repayment of money, whether as principal or as surety and whether present, future, actual
or contingent. 

  

	2	The Loan and its Purpose 

  

	2.1	Agreement to lend 

Subject to the terms and conditions of this Agreement, and in reliance on each of the representations and warranties made or to be made in
or in accordance with each of the Security Documents: 
  

	2.1.1 	each of the Lenders agrees to advance to the Borrower its Commitment of an aggregate principal amount not exceeding the Buyer Credit Maximum Amount to be used by the
Borrower for the purposes referred to in Recital (B); and 

  

	2.1.2 	each of the Lenders agrees to advance to the Borrower its Commitment of an aggregate principal amount not exceeding the Commercial Loan Maximum Amount to be used by the
Borrower for the purposes referred to in Recital (C). 

  

	2.2	Drawdown Request 

 The
Borrower may request a Drawing to be advanced in one amount on any Business Day prior to the relevant Availability Termination Date by delivery to the Agent of a duly completed Drawdown Notice not later than 10 a.m. (Paris time) on a Business Day
falling not more than ten (10) and not fewer than three (3) Business Days before the proposed Drawdown Date. A Drawdown Notice shall be effective on actual receipt by the Agent and, once given, shall, subject as provided in clause 13.8, be
irrevocable. 
  

	2.3	Drawings 

  

	2.3.1 	The amount of each Drawing shall, subject to the following provisions of this clause 2.3, be for such amount as is specified in the Drawdown Notice for that Drawing.

  

	2.3.2 	Drawings may only be made on Business Days falling within the Availability Period. 

 

	2.3.3 	Ancillary Cost Advances shall, subject to clause 3, only be available in minimum amounts of one million Dollars ($1,000,000)
(provided that this threshold shall not apply to Ancillary Cost Advances drawn to pay the Ancillary Costs described in part (c) of the definition thereof) and shall only be
available for application in or towards payment of expenditure which the Borrower has certified and evidenced in accordance with clause 3.1.4 and in any event an Ancillary Cost Advance shall only be available if such Ancillary Cost Advance will not,
when aggregated with all previous Ancillary Cost Advances, equal a sum in excess of $36,000,000. 

  

	2.3.4 	The Borrower shall be entitled to draw an Ancillary Cost Advance on the first Drawdown Date up to a maximum amount of
$16,750,00021,200,000 for the purpose of repaying shareholder loans to the extent required to achieve a Borrower’s Leverage Ratio of 4:1. 

 

	2.3.5 	Each Ancillary Cost Advance may be made on any date. 

  

	2.3.6 	Contract Instalment Advances shall, subject always to clauses 2.1 and 3, be in the maximum amount not exceeding the
relevant instalment amount of the Contract Price set out in each column (3) of Part A of Schedule 7
as such sumsinstalment amounts may be amended following any permitted increase in the Contract Price and shall only be available for application (a) in or towards
payment of instalments of the Contract Price which have become due and payable by the Borrower pursuant to the Building Contract or (b) in or towards reimbursement to the Borrower of such part of any instalment amount of the Contract Price as
set out in column (3) of Part A of Schedule 7 which has become due and payable by
the Borrower pursuant to the Building Contract and which the Borrower has satisfied the Agent has been paid by the Borrower or by the Sponsors on behalf of the Borrower. 

  
 20 

	2.3.7 	No Drawing shall be available to the Borrower unless (a) the Agent or the Borrower shall have first received such amount (the “Relevant Amount”)
by way of contributions of Minimum Borrower Shareholders’ Equity and/or Additional Shareholders’ Equity which, when aggregated with the amounts received by the Agent from the Lenders in respect of such Drawing (and in the case of
amounts received by the Borrower, the Agent is satisfied that such amount is or has been or is to be applied in meeting the instalments of Contract Price or Ancillary Cost in respect of which the relevant Drawing is to be applied (and for the
avoidance of doubt the instalments of Ancillary Costs in respect of which Drawings are to be applied shall not when aggregated with all Ancillary Costs in respect of which an Ancillary Cost Advance has been made exceed $36,000,000)) is equal to or
greater than one fifth (1/5th) of the Total Project Cost as at the date of the relevant Drawing (and including such Drawing) and (b) the aggregate of the Drawing and the Relevant Amount shall be not less than the total amount of the
relevant Ancillary Costs and/or the relevant instalment of the Contract Price in respect of which the relevant Drawing is to be applied. 

  

	2.3.8 	The aggregate amount which may be drawn down under this Agreement shall never exceed the lesser of (a) 80% of the Total Project Cost and (b) $210,000,000.

  

	2.3.9 	Each Drawing (together with the Relevant Amount of the Minimum Borrower Shareholders’ Equity and/or Additional Shareholders’ Equity paid to the Agent pursuant
to clause 2.9 in respect of that Drawing) shall unless the Agent shall determine otherwise be paid by the Agent on behalf of the Borrower directly to the payee(s) in respect of which such Drawing is made provided that in respect of any Ancillary
Cost in respect of which an Ancillary Cost Advance may be made under this Agreement (excluding for these purposes the KEIC Insurance Premium) of less than $1,000,000 in aggregate or where the Agent is satisfied that the Borrower has settled the
amount due to any such payee(s) in full the Agent shall pay that part of the relevant Drawing directly to the Borrower. 

  

	2.3.10 	TheSubject to clause 2.3.14, the Agent shall be entitled to set off from any Drawing
any interest, fees or commissions or other sums due and payable by the Borrower to the Lenders or any of them and/or to the Agent and/or to the Security Trustee and/or to the KEIC Agent and/or to the Swap Providers under this Agreement or any of the
other Security Documents and to apply the same in settlement of such interest, fees or commissions or other sums so due and payable. 

  

	2.3.11 	The first Drawing (which includes the first Contract Instalment Advance) shall be pro-rated between the Buyer Credit and the Commercial Loan PROVIDED THAT any
Ancillary Cost Advance included in such Drawing, including but not limited to the KEIC Premium, shall be funded 100% by the portion of such Drawing funded by the Commercial Loan. The remaining components of such Drawing shall be funded by such
percentage of the Buyer Credit and Commercial Loan as is required to ensure that such Drawing, taken as a whole, is pro-rated between the Buyer Credit and the Commercial Loan. 

 

	2.3.11 	2.3.12 The first Drawing (which includes the first Contract Instalment Advance) shall be pro-rated between the Buyer Credit and the Commercial Loan
PROVIDED THAT any Ancillary Cost Advance included in such Drawing, including but not limited to the KEIC Premium, shall be funded 100% by the portion of such Drawing funded by the Commercial Loan. The remaining components of such Drawing shall be
funded by such percentage of the Buyer Credit and Commercial Loan as is required to ensure that such Drawing, taken as a whole, is pro-rated between the Buyer Credit and the Commercial Loan. 

 

	2.3.12 	2.3.13 Further Drawings (excluding the Drawing due on the Delivery Date) shall each be funded (a) in respect of a Contract Instalment Advance, by
the Buyer Credit in an amount equal to the lesser of US$ 9,240,000 and 50% of the amount of such Contract Instalment Advance with the remainder of such Contract Instalment Advance funded by the Commercial Loan and (b) in respect of any
Ancillary Costs Advance included in such Drawing, 100% by the Commercial Loan. 

  

	2.3.13 	2.3.14 The Drawing due on the Delivery Date (which includes the Delivery Date Advance) shall be funded (a) in respect of any Ancillary Costs
Advance included in such Drawing, 100% by the Commercial Loan and (b) in respect of the Delivery Date Advance, by such percentage of the Buyer Credit and Commercial Loan as is required to ensure that, on the Delivery Date, the Loan Outstandings
are pro-rated between the Buyer Credit and the Commercial Loan. 

  

  
 21 

	2.3.14 	Where an Ancillary Costs Advance is drawn to pay interest on the Loan (Whether the Commercial Loan or the
Buyer Credit) falling due for payment and/or accruing on or before the Delivery Date, the portion of such Ancillary Costs Advance corresponding to such interest shall be funded 100% by the Commercial Loan in accordance with clauses 2.3.11 to 2.3.13
(inclusive) and shall be applied by the Agent in satisfaction of the Borrower’s obligation to pay such interest (and the Borrower’s obligation to pay such interest shall be deemed to have been satisfied upon the making of such Ancillary
Costs Advance). 

  

	2.4	Lenders’ participation 

 Subject to clauses 2 and 3, the Agent shall promptly notify each relevant Lender of the receipt of a Drawdown Notice and of the date on which the Drawing is to be made, following which each
relevant Lender shall advance its proportionate share of the relevant Drawing to the Borrower through the Agent on the relevant Drawdown Date. 
  

	2.5	Availability Termination Date 

 No Lender shall be under any obligation to advance all or any part of its Commitment after the relevant Availability Termination Date. 

 

	2.6	Several obligations 

  

	2.6.1 	The obligations of each Lender Finance Party under this Agreement are several. No Lender Finance Party is responsible for the obligations of any other Lender Finance
Party. Even if one or more Lender Finance Parties fails to perform its obligations, the other Lender Finance Parties will continue to perform their obligations and will be able to enforce their rights in respect of the other parties to this
Agreement. 

  

	2.6.2 	The obligations of the Borrower under this Agreement are as follows: 

  

	 	(a)	the Borrower will pay to the Security Trustee, when they are due for payment, the full amount of the Loan and all other amounts (including any amounts payable under the
Swap Agreements or any of them, interest, commission and expenses) payable by the Borrower under the Security Documents; 

  

	 	(b)	the Borrower will pay to the Agent for the account of each Lender, when they are due for payment, that proportion of the Loan which was lent by that Lender and all
interest, commission and other amounts payable in relation to it; 

  

	 	(c)	the Borrower will pay to the Agent, when they are due for payment, all amounts owing to it under the Security Documents; 

 

	 	(d)	the Borrower will pay to the KEIC Agent, when they are due for payment, all amounts owing to it under the Security documents; 

 

	 	(e)	the obligations of the Borrower to (on the one hand) the Security Trustee and (on the other hand) each other Lender Finance Party are several; 

 

	 	(f)	payment either to the Security Trustee or to another Lender Finance Party of an amount which is due to both of them will reduce both of those liabilities by that
amount; and 

  

	 	(g)	if an amount would otherwise be payable under this clause 2.6 to the same person in two different capacities, the Borrower will only have an obligation to pay that
amount once. 

  
 22 

	2.6.3	Each Lender Finance Party can enforce its rights without joining the Security Trustee or any other Lender Finance Parties. However, the Security Documents listed in
clause 8.1 below can only be enforced by the Security Trustee. 

  

	2.7	Application of Loan 

Without prejudice to the obligations of the Borrower under this Agreement, no Lender Finance Party shall be obliged to concern itself with
the application of the Loan by the Borrower. 
  

	2.8	Loan facility and control accounts 

 The Agent will open and maintain such loan facility account or such other control accounts as the Agent shall in its discretion consider necessary or desirable in connection with the Loan. 

 

	2.9	Minimum Borrower Shareholders’ Equity and Additional Shareholders’ Equity 

The Borrower hereby agrees with the Agent that notwithstanding any other provision of this Agreement subject as contemplated in clause
2.3.7 each Relevant Amount of the Minimum Borrower Shareholders’ Equity and/or Additional Shareholders’ Equity shall be paid to the Agent and each such Relevant Amount paid shall be aggregated with each relevant Drawing and paid by the
Agent pursuant to the provisions of clause 2.3.9. 
  

	3	Conditions precedent and subsequent for the Loan  

  

	3.1	Conditions precedent 

  

	3.1.1	Before any Lender shall have any obligation to advance the first Drawing under the Loan the Borrower shall deliver or cause to be delivered to or to the order of the
Agent all of the documents and other evidence listed in Part I of Schedule 3 which shall be delivered not later than 4 Business Days before the day on which the Drawdown Notice for the first Drawing is given save for those documents or other
evidence which are expressly required to be provided on the first Drawdown Date which shall be delivered on such first Drawdown Date. 

  

	3.1.2	The obligation of the Lenders to make any Contract Instalment Advance shall be subject to the further condition that the Agent shall have received not later than 4
Business Days before the day on which that Contract Instalment Advance is intended to be made, the documents and evidence specified in Part 2 of Schedule 3 in form and substance satisfactory to the Agent (save for the invoice and the Drawdown Notice
referred to in paragraphs (a) and (e) of Part 2 of Schedule 3 which shall be provided not later than 3 Business Days prior to the relevant Drawdown Date). 

 

	3.1.3	The obligation of the Lenders to make the Delivery Date Advance shall be subject to the condition that the Agent, shall have received, on or prior to the relevant
Delivery Date, the documents and evidence specified in Part 3 of Schedule 3 in form and substance satisfactory to the Agent. 

  

	3.1.4	The obligation of the Lenders to make any Ancillary Cost Advance shall be subject to the further condition that the Agent shall have received not later than 4 Business
Days before the drawdown of any Ancillary Cost Advance, invoices or pro-forma invoices or, (save in respect of Ancillary Costs as described in sub-paragraph (f) of the definition thereof in respect of which invoices shall be required) where
invoices or pro-forma invoices cannot be made available by the Borrower, a certificate from the Borrower in form and substance satisfactory to the Agent, in each case evidencing the Ancillary Costs incurred or, in the case of pro-forma invoices or
certificates from the Borrower, to be incurred within the next following period not exceeding 3 Months or other written evidence in each case substantiating to the reasonable satisfaction of the Agent that the Ancillary Costs in respect of which
such Ancillary Cost Advance is requested have been incurred and discharged or will be discharged following the drawdown of the Ancillary Cost Advance. 

  
 23 

	3.2	Further conditions precedent 

 The Lenders will only be obliged to advance a Drawing in respect of the Vessel specified in any Drawdown Notice if on the date of the Drawdown Notice and on the proposed Drawdown Date: 

 

	3.2.1	no Event of Default, Potential Event of Default or Mandatory Prepayment Event is continuing unremedied or unwaived or would result from the advance of that Drawing;

  

	3.2.2	the representations made by the Borrower under clause 4 are true in all material respects; 

 

	3.2.3	that Drawing will not, when aggregated with all previous Drawings, increase the outstanding amount of the Loan to a sum in excess of the Maximum Loan Amount and will
not increase the outstanding amount of the Buyer Credit to a sum in excess of the Buyer Credit Maximum Amount or of the Commercial Loan to a sum in excess of the Commercial Loan Maximum Amount; and 

 

	3.2.4	the Borrower shall have on or prior to the First Drawing, entered into one or more 12 year forward starting Swap Agreements in form and substance satisfactory to the
Agent with each of the Swap Providers pursuant to which it will hedge not less than one hundred and ninety million Dollars ($190,000,000) of the Loan (representing approximately ninety per cent (90%) of its interest rate exposure under the
Loan) for the period from and including the Delivery Date up to and including the Maturity Date. The Swap Margin applicable to each Swap Agreement entered into between any of the Swap Providers and the Borrower shall be as set out in the Swap Margin
Side Letter. 

  

	3.3	Delivery conditions precedent 

  

	3.3.1	Whether or not a Drawing is advanced on the Delivery Date, the Borrower undertakes to deliver or to cause to be delivered to the Agent on the Delivery Date the
additional documents and other evidence listed in Part 3 of Schedule 3. 

  

	3.3.2	The Borrower shall on the Delivery Date enter into a spot start Swap Agreement or Swap Agreements with each of the Swap Providers to ensure that, together with the
forward starting swap agreements, no less than ninety-five per cent (95%) of its interest rate exposure under the Loan is hedged. 

  

	3.4	No Waiver 

 If the Lenders
in their sole discretion agree to advance a Drawing to the Borrower before all of the documents and evidence required by clause 3.1, clause 3.3 and/or clause 3.5 have been delivered to or to the order of the Agent, the Borrower undertakes to deliver
all outstanding documents and evidence to or to the order of the Agent no later than ten (10) Business Days after the Drawdown Date or such other date specified by the Agent acting on the instructions of the Majority Lenders. 

The advance of a Drawing under this clause 3.4 shall not be taken as a waiver of the Lenders’ right to require production of all the
documents and evidence required by clauses 3.1, 3.2 and 3.3. 
  

	3.5	Form and content 

 All
documents and evidence delivered to the Agent under this clause 3 shall: 
  

	3.5.1	be in form and substance reasonably acceptable to the Agent; and 

  

	3.5.2	if required by any vessel or security registry or in connection with any legal opinion to be provided pursuant to Schedule 3, be certified, notarised, legalised or
attested in a manner acceptable to such registry or person providing the legal opinion. 

  
 24 

	3.6	Waiver of conditions precedent 

 The conditions specified in this clause 3 are inserted solely for the benefit of the Lenders and may be waived by the Agent (acting on the instructions of the Majority Lenders) in whole or in part with or
without conditions. 
  

	4	Representations and Warranties  

  

	4.1	Representations and Warranties 

 The Borrower represents and warrants to each of the Lender Finance Parties as follows: 
  

	4.1.1	Due Incorporation 

 Each
of the Security Parties is a corporation or limited liability company duly organised or formed under the laws of its jurisdiction of incorporation, organisation or formation (as the case may be) with power to carry on their respective business as
they are now being conducted and to own their respective property and other assets. 
  

	4.1.2	Corporate Power 

 The
Borrower has power to execute, deliver and perform its obligations under this Agreement and each of the other Relevant Documents to which it is a party and to borrow the Commitments and each of the other Security Parties has power to enter into the
Relevant Documents to which it is a party and to exercise its rights and perform its obligations under such Relevant Documents; all corporate and other action required by each of the Security Parties to authorise its execution of the Relevant
Documents to which it is a party and the performance by it of its obligations thereunder has been duly taken. 
  

	4.1.3	Binding Obligations 

 The
obligations expressed to be assumed by each of the Security Parties in the Relevant Documents to which it is a party are legal, valid and binding obligations, enforceable in accordance with the terms of the Relevant Documents and no limit on any of
their powers will be exceeded as a result of the borrowings, granting of security or giving of guarantees contemplated by the Relevant Documents or the performance by any of them of any of their obligations thereunder. 

 

	4.1.4	No conflict with other obligations 

 The execution and delivery of, the performance of its obligations under, and compliance with the provisions of the Relevant Documents to which each is a party by the relevant Security Parties will not:

  

	 	(a)	contravene any existing applicable law, statute, rule or regulation or any judgment, decree or permit to which the Borrower or, any other Security Party is subject;

  

	 	(b)	conflict with, or result in any breach of any of the terms of, or constitute a Potential Event of Default under, any agreement or other instrument to which the Borrower
or, any other Security Party is a party or is subject or by which it or any of its property is bound; 

  

	 	(c)	contravene or conflict with any provision of the constitutional documents of the Borrower or, any other Security Party; or 

 

	 	(d)	result in the creation or imposition of or oblige the Borrower or any other Security Party, to create any Encumbrance (other than a Permitted Encumbrance) on any of
their respective undertakings, assets, rights or revenues. 

  
 25 

	4.1.5	No Litigation 

 No
litigation, arbitration or administrative proceeding is taking place, pending or, to the knowledge of the officers of the Borrower, threatened in writing against any of the Security Parties which, in respect of the Security Parties other than the
Borrower, has or could reasonably be expected to have a Material Adverse Effect. 
  

	4.1.6	Accounts 

 The certified
true and complete copies of the audited annual accounts and unaudited semi-annual accounts (as applicable) of the Borrower for the period ending on 31 December 2007 and of each Sponsor for the most recent financial year of each such Sponsor and
delivered to the Agent on or prior to the date of this Agreement pursuant to Schedule 3, Part 1, were prepared in accordance with GAAP, give (in conjunction with the notes thereto) a true and fair view of the financial condition of each such party
at the date as of which they were prepared and the results of that party’s operations during the financial period then ended. 
  

	4.1.7	No Filing or Stamp Taxes 

It is not necessary to ensure the legality, validity, enforceability or admissibility in evidence of any of the Relevant Documents that
they or any other instrument be notarised, filed, recorded, registered or enrolled with any court, public office or elsewhere in any Relevant Jurisdictionthe jurisdiction
of incorporation of the Borrower (other than the Registrar of Companies for England and Wales, or the relevant maritime registry, to the extent applicable) or that any stamp, registration or similar tax or charge be paid on or in relation to any
of such Relevant Documents and each of the Relevant Documents is in the proper form for enforcement in each Relevant Jurisdictionthe jurisdiction of incorporation of the
Borrower. 
  

	4.1.8	No Immunity 

 None of the
Security Parties or any of their respective assets is entitled to immunity on the grounds of sovereignty or otherwise from any legal action or proceeding including, without limitation, suit, attachment prior to judgement, execution or other
enforcement. 
  

	4.1.9	Choice of Law and Judgments 

 The choice of English law to govern the Security Documents (other than the Mortgage and, in the event that the Share Charges are not governed by English law, the Share Charges) and the laws of the Flag
State to govern the Mortgages and, in the event that the Share Charges are not governed by English law, the governing law of the Share Charges and the submission by the Security Parties to the jurisdiction of the English courts in respect of the
Security Documents (other than the Mortgage and, in the event that the Share Charges are not governed by English law, the Share Charges) are valid and binding. 
  

	4.1.10	Consents Obtained 

 Every
consent, Authorisation, licence or approval of, or registration with or declaration to, governmental or public bodies or authorities or courts required by any Security Party to authorise, or required by each such party in connection with, the
execution, delivery, validity, enforceability or admissibility in evidence of each of the Relevant Documents or the performance by each such party of its obligations under the Relevant Documents to which each is a party has been obtained or made
(other than consents, Authorisations, licences, approvals, registrations or declarations that, as at the date of the representation, are not required to be obtained) and is in full force and effect and there has been no default in the observance of
any of the conditions or restrictions (if any) imposed in, or in connection with, any of the same. 
  

	4.1.11	No Undisclosed Liabilities 

The Borrower has no material liabilities (contingent or otherwise) which were not disclosed in the accounts referred to in clause 4.1.6
(or by the notes thereto) or reserved against therein nor any unrealised or anticipated losses arising from commitments entered into by it which were not so disclosed or reserved against therein. 

  
 26 

	4.1.12	Money Laundering 

 No
breach of any law or regulatory measure relating to “money laundering” as defined in Article 1 of the Directive (91/308/EEC) of the Council of the European Communities will result from the borrowing of the Loan by the Borrower or from
the performance by any of the Security Parties of any of their obligations under any of the Relevant Documents to which each is a party. 
  

	4.1.13	Financial Indebtedness 

Except as set forth in Exhibit A, other than in respect of the Loan pursuant to this Agreement or as otherwise permitted by this
Agreement, it has not created, incurred, assumed or allowed to exist any Financial Indebtedness, entered into any finance lease or undertaken any capital commitment. 
  

	4.1.14	Environmental Matters 

Except as may already have been disclosed by the Borrower to the Agent in writing: 

 

	 	(a)	all Environmental Laws applicable to the Vessel have been complied with by each Environmental Affiliate and all consents, licences and approvals required under such
Environmental Laws have been obtained and complied with by each Environmental Affiliate (other than such consents, licences and approvals that, as at the date of the representation, are not required to be obtained); and 

 

	 	(b)	no Environmental Claim has been made or threatened against the Borrower or the Vessel and no Environmental Claim in respect of the Vessel has been made or threatened
against any other Environmental Affiliate or is pending against any such Environmental Affiliate or the Vessel and which has not been fully satisfied and which would or might reasonably result in liabilities in excess of an aggregate of $1,000,000;
and 

  

	 	(c)	there has been no Environmental Incident which could or might reasonably result in claims in excess of an aggregate of $1,000,000.  

 

	4.1.15	Pari Passu 

 The
obligations of the Security Parties under the Security Documents are direct, general and unconditional obligations and rank at least pari passu with all the Security Parties’ other present and future unsecured unsubordinated indebtedness other
than obligations mandatorily preferred by law and not contract. 
  

	4.1.16	No Deductions or Withholding 

 No Taxes are imposed by way of or withholding or otherwise from any payment to be made by any Security Party under any of the Security Documents to which it is a party. 

 

	4.1.17	Information 

 The
information, exhibits and reports furnished by any Security Party to any of the Lender Finance Parties in connection with the negotiation and preparation of the Security Documents are true and accurate in all material respects and not misleading, do
not omit material facts and all reasonable enquiries have been made to verify the facts and statements contained therein and the Borrower is not aware of any material facts or circumstances which have not been disclosed and which might, if
disclosed, have reasonably been expected to adversely affect the decision of a person considering whether or not to make loan facilities of the nature contemplated by this Agreement available to the Borrower and/or to enter into the transactions
contemplated in this Agreement and the other Security Documents, Provided that, the Borrower does not make the representations in this clause 4.1.17 in respect of information, exhibits or reports regarding Angola LNG, the Angola LNG Project or the
Time Charterer save that such information, exhibits or reports which have been provided by the Borrower to the Lender Finance Parties have been provided by the Borrower in good faith. 

  
 27 

	4.1.18	Solvency 

  

	 	(a)	None of the Security Parties is unable, or admits or has admitted its inability, to pay its debts or has suspended making payments in respect of any of its debts.

  

	 	(b)	None of the Security Parties by reason of actual or anticipated financial difficulties, has commenced, or intends to commence, negotiations with one or more of its
creditors with a view to rescheduling any of its indebtedness. 

  

	 	(c)	No moratorium has been, or may, in the reasonably foreseeable future be, declared in respect of any indebtedness of any Security Party. 

 

	4.1.19	No Winding-up 

 None of
the Security Parties has taken any corporate action nor have any other steps been taken or legal proceedings been started or (to the best of the Borrower’s knowledge and belief) threatened against any Security Party for its winding-up,
dissolution, administration or reorganisation or for the appointment of a receiver, administrator, administrative receiver, trustee or similar officer of it or of any or all of its assets or revenues which (in relation to Security Parties other than
the Borrower) might have a Material Adverse Effect. 
  

	4.1.20	Event of Default/no other Defaults 

  

	 	(a)	None of the Security Parties is in material breach of or in default under any agreement to which it is a party or which is binding on it or any of its assets.

  

	 	(b)	No Event of Default or Potential Event of Default is continuing unremedied or unwaived. 

 

	4.1.21	Ownership of the Borrower 

The Sponsors, directly or indirectly, legally and beneficially own all of the shares in the Borrower and will (subject to the provisions
of clause 9.2.17) continue to, directly or indirectly, own all of the shares in the Borrower in the following percentages: 
  

					
	 Teekay:-
	  	 	33	% 
	 NYK:-
	  	 	33	% 
	 Mitsui :-
	  	 	34	% 

  

	4.1.22	No Default under Building Contract or Refund Guarantee 

 The Borrower is not in default of any of its obligations under the Building Contract or any of its obligations upon the performance or observance of which depend the continued liability of the Refund
Guarantor in accordance with the terms of the Refund Guarantee. 
  

	4.1.23	No Encumbrance in respect of pre-delivery security 

 The Borrower has not previously charged, encumbered or assigned the benefit of any of its rights, title and interest in or to the Building Contract, the Refund Guarantee, the Supervision Agreement, the
Swap Agreements or the Depot Spares Sharing Agreement and such benefit and all such rights, title and interest are freely assignable and chargeable in the manner contemplated by the Security Documents. 

  
 28 

	4.1.24	The Vessel 

 The Vessel
will on the Delivery Date be: 
  

	 	(a)	in the absolute ownership of the Borrower who will on and after the Delivery Date thereof be the sole, legal and beneficial owner of the Vessel;

  

	 	(b)	registered in the name of the Borrower under the laws and flag of the Bahamas; 

 

	 	(c)	operationally seaworthy and in every way fit for service; and 

  

	 	(d)	classed with the classification referred to in clause 9.6.3(b) free of any overdue recommendations and conditions affecting the Vessel’s class of the
Classification Society. 

  

	4.1.25	Vessel’s employment 

The Vessel will not on or before the Delivery Date thereof be subject to any charter or contract other than the Time Charter or to any
agreement to enter into any charter or contract which, if entered into after the date of the Mortgage would have required the consent of the Agent or Security Trustee and on the Delivery Date thereof there will not be any agreement or arrangement
whereby the Earnings may be shared with any other person. 
  

	4.1.26	Freedom from Encumbrances 

Neither the Vessel nor its Earnings, Insurances or Requisition Compensation, the Time Charter, the Accounts, nor the Depot Spares Sharing
Agreement, nor any other properties or rights which are, or are to be, the subject of any of the Security Documents nor any part thereof will be, on the Delivery Date of the Vessel, subject to any Encumbrance other than any Permitted Encumbrance.

  

	4.1.27	Copies true and complete 

The copies of each of the Time Charter, the Building Contract, the Refund Guarantee, the Supervision Agreement, the Depot Spares Sharing
Agreement, the Tripartite Agreement and the Management Agreement delivered or to be delivered to the Agent are or will when delivered be, a true and complete copies of such documents, will when delivered constitute valid and binding obligations of
the parties thereto enforceable in accordance with its terms and there have been no material amendments or variations to or defaults under the Building Contract and there have been no amendments or variations to or defaults under the Time Charter.

  

	4.2	Repetition of representations and warranties 

 On the Execution Date and, in respect of the Relevant Documents other than this Agreement on the execution date of such other Relevant Document, and as of each Drawdown Date and on each Interest Payment
Date the Borrower shall (a) be deemed to repeat the representations and warranties in clause 4.1 as if made with reference to the facts and circumstances existing on such day and (b) in respect of clause 4.1.6 shall be deemed to refer to
the then latest audited financial statements delivered to the Agent pursuant to clause 9.1.5. 
  

	4.3	Representations Limited 

The representations and warranties of the Borrower in this clause 4 are subject to: 

 

	4.3.1	the principle that equitable remedies are remedies which may be granted or refused at the discretion of the court; 

 

	4.3.2	the limitation of enforcement by laws relating to bankruptcy, insolvency, liquidation, reorganisation, court schemes, moratoria, administration and other laws generally
affecting or limiting the rights of creditors; 

  
 29 

	4.3.3	the time barring of claims under any applicable limitation acts; 

  

	4.3.4	the possibility that a court may strike out provisions for a contract as being invalid for reasons of oppression, undue influence or similar; 

 

	4.3.5	any other reservations or qualifications of law expressed in the legal opinions obtained by the Agent as referred to in Schedule 3 Part 1, paragraph (I) in
connection with this Agreement or the Security Documents; and 

  

	4.3.6	the representations and warranties made on the Execution Date in respect of the Relevant Documents shall expressly be limited to this Agreement (and none of the other
Security Documents) and only those Project Documents which, as at the Execution Date, have been executed by the Borrower. 

  

	5	Repayment and Prepayment 

  

	5.1	Repayment of Loan 

 The
Borrower agrees: 
  

	5.1.1	to repay the Buyer Credit to the Agent for the account of the Lenders by forty eight (48) consecutive annuity style quarterly Repayment Instalments in the amounts,
subject to the provisions of this Agreement, set out in Part B of Schedule 7. The first Repayment Instalment will fall due on the date falling three (3) Months after the Delivery
Date and each succeeding Repayment Instalment shall be payable quarterly in arrears at three (3) Monthly intervals thereafter save for the final Repayment Instalment which shall be payable on the Maturity Date; and 

 

	5.1.2	to repay the Commercial Loan by one (1) instalment to be paid on the Maturity Date. 

 

	5.2	Reduction of Repayment Instalments 

 If, following the Availability Termination Date, the aggregate amount advanced to the Borrower under the Buyer Credit is less than the Buyer Credit Maximum Amount, the amount of each Repayment Instalment
of the Buyer Credit shall be reduced pro rata so that the aggregate sum of all such Repayment Instalments shall be equal to the aggregate amount of the Buyer Credit actually advanced. 

 

	5.3	Reborrowing 

 The Borrower
may not reborrow any part of the Loan which is repaid or prepaid. 
  

	5.4	Prepayment and Cancellation 

  

	5.4.1	The Borrower may prepay, without premium or penalty but subject to clause 5.10, the Loan Outstandings in whole or in part, or cancel the Loan in whole or in part, in
each case in a minimum amount of five million Dollars ($5,000,000) or any larger sum which is an integral multiple of one million Dollars ($1,000,000) (or in either case as otherwise may be agreed by the Agent) and provided that the Borrower has
first given to the Agent not fewer than ten (10) days prior written notice in respect of a prepayment of all or part of the Loan Outstandings or fifteen (15) days in respect of a cancellation in whole or part of the Commitment in each such
case expiring on a Business Day of their intention to do so. Any notice pursuant to this clause 5.4 once given shall be irrevocable and shall (in the case of a prepayment) oblige the Borrower to make the prepayment referred to in the notice on the
Business Day specified in the notice, together with all interest accrued on the amount prepaid and all accrued and unpaid Commitment Fees up to and including that Business Day and any and all other amounts then due and payable under this Agreement
and any of the other Security Documents including, without limitation, any sums payable under the indemnity in clause 15 and all amounts due and payable under the Swap Agreements. Any cancellation of part (but not the whole) of the Commitment shall
be subject to the condition that the Borrower has demonstrated to the satisfaction of the Agent (acting reasonably) that it will have sufficient funds to comply with its obligations under the Relevant Documents following any such cancellation.

  
 30 

	5.5	Mandatory Prepayment on Total Loss 

 In the event that the Vessel becomes a Total Loss on or following the Delivery Date thereof, on the earlier to occur of (a) the date of receipt of the proceeds of the Total Loss and (b) the date
falling one hundred and eighty (180) days after the occurrence of the Total Loss (the “Reduction Date”), the Borrower shall prepay the Loan together with all interest accrued thereon up to and including the day of
prepayment and all other amounts then due and payable under this Agreement or any of the other Security Documents including, without limitation, any sums payable under the indemnity in clause 15 and all amounts due and payable under the Swap
Agreements. 
  

	5.6	Prepayment on Non Delivery/Building Contract default/termination 

 In the event that there is a material breach by the Builder of the Building Contract that has not been cured within the applicable grace period provided therein, or the Building Contract is cancelled,
terminated, rescinded or frustrated for any reason that has not been cured within the applicable grace period provided therein or if the Builder assigns, transfers, sells or otherwise disposes of any of its right, title or interest in or to the
Building Contract or the Vessel or purports to do so or takes any action to so assign, transfer, sell or otherwise dispose of any or all such rights, title or interest or, prior to the Delivery Date the Vessel becomes a Total Loss the Borrower
shall, if so requested by the Agent in writing, and without prejudice to the Agent’s rights pursuant to clause 10.1 and/or the rights of the Security Trustee under the Security Documents where any of the events described above constitute an
Event of Default, be obliged to prepay the Loan immediately together with all interest accrued thereon up to and including the day of prepayment and all other amounts then due and payable under this Agreement or any of the other Security Documents
including, without limitation, any sums payable under the indemnity in clause 15 and all amounts due and payable under the Swap Agreements and the undrawn Commitments shall be cancelled. 

 

	5.7	Prepayment on Termination of Refund Guarantee 

 If, prior to the delivery to and acceptance by the Borrower from the Builder of the Vessel, the Refund Guarantee is repudiated, cancelled, amended without the Agent’s prior written consent (acting on
the Instructions of all Lenders), rescinded or otherwise terminated, the Loan shall become prepayable and shall be prepaid immediately and without demand together with all interest accrued thereon up to and including the date of prepayment and all
other amounts then due and payable under this Agreement or any of the other Security Documents including, without limitation, any sums payable under the indemnity in clause 15 and all amounts due and payable under the Swap Agreements. 

 

	5.8	Additional Mandatory Prepayment Events 

 Upon the occurrence of any of the following events the Loan shall immediately become repayable and the Borrower shall immediately prepay the Loan together with all interest accrued thereon up to and
including the date of prepayment together with all other amounts then due and payable under this Agreement and the other Security Documents including, without limitation, any indemnity sums payable under clause 15 and all amounts due and payable
under the Swap Agreements. 
  

	5.8.1	Non-Delivery of the Vessel: the Vessel is not delivered to, and accepted by, the Borrower under the Building Contract and/or by the Time Charterer under the Time
Charter prior to the date falling 290 days after the Scheduled Delivery Date (or such later date as the Agent acting on the instructions of the Majority Lenders (acting in their absolute discretion), may agree in writing); or

  

	5.8.2	Sale/Early Termination: the Vessel is sold or the chartering of the Vessel is terminated early pursuant to the exercise by the Time Charter of its rights under
the Time Charter; or 

  
 31 

	5.8.3	Invalidity: (i) any of the Security Documents or the Refund Guarantee shall at any time and for any reason become invalid, illegal or unenforceable or
impossible to perform or cease to remain in full force and effect; or (ii) any of the Project Documents shall at any time and for any reason become invalid, illegal or unenforceable or impossible to perform or cease to remain in full force and
effect unless (A) in respect of the Security Documents, the relevant Security Document is amended or replaced to the reasonable satisfaction of the Agent acting on the instructions of all of the Lenders forthwith in the case of this Agreement,
the Mortgage, the Refund Guarantee and the Deed of Covenants or within 14 days in the case of any other Security Document and (B) where any such events have occurred in respect of the Time Charter, the Borrower has, within 30 days of the
occurrence of such events entered into a new time charter and with a new time charterer in each case in all respects satisfactory to the Agent acting on the instructions of all the Lenders and to KEIC; or 

 

	5.8.4	Termination of Time Charter: the Time Charter is terminated by the Borrower or the Time Charterer following the occurrence of a breach of the Time Charter
entitling it to take such action or is cancelled or becomes frustrated for any reason whatsoever unless the Borrower has within 30 days of the date of such occurrence entered into a replacement time charter and with a new time charterer in each case
in all respects satisfactory to the Agent (acting on the instructions of all Lenders); or 

  

	5.8.5	Time Charterer failure to pay: the Time Charterer fails to pay any sum due and payable by it to any of the Lender Finance Parties or to the Borrower under any of
(a) the Security Documents or (b) the Project Documents to which it is a party at the time, in the currency and in the manner stipulated thereunder unless, where such failure to pay is a failure to pay any sum due and payable by it under
any Project Document, following expiry of any applicable grace period thereunder, such failure in the opinion of the Agent (acting on the instructions of all Lenders (acting reasonably)) does not and will not be likely to have a Material Adverse
Effect; or 

  

	5.8.6	Time Charter’s breach: the Time Charterer commits any breach of or omits to observe any of its obligations or undertakings expressed to be assumed by it
under (a) any of the Security Documents (and such failure is not remedied within fifteen (15) days after the date the Agent has given notice thereof to the Borrower and the Time Charterer) and/or (b) any of the Project Documents to
which it is a party (other than those referred to in clause 5.8.5) unless, where such breach or omission has occurred under a Project Document following expiry of any applicable grace period therein, such breach or omission, in the opinion of the
Agent (acting on the instructions of all Lenders (acting reasonably)), does not and will not be likely to have a Material Adverse Effect. 

  

	5.8.7	War: if the country of registration of the Vessel becomes involved in war (whether or not declared) or civil war or is occupied by any other power and the Agent
reasonably considers that, as a result, the security conferred by the Security Documents is materially prejudiced. 

  

	5.8.8	Failure to Pay: the Builder or the Refund Guarantor fails to pay any amount payable by it under any of the Security Documents or the Refund Guarantee at the
time, in the currency and otherwise in the manner specified therein (and so that, for this purpose, sums payable on demand shall be treated as having been paid at the stipulated time if paid within five (5) days of demand) unless in respect of
scheduled payments the Borrower demonstrates to the satisfaction of the Agent that such failure has occurred by reason solely of banking error and such sum remains unpaid for no longer than five (5) days after the date on which it receives
notice from the Agent of such failure; or 

  

	5.8.9	Other Obligations: the Builder or the Refund Guarantor fails duly to perform or comply with any other term or condition of any other Security Document to which
it is a party when such failure is in the opinion of the Agent (acting on the instructions of the Majority Lenders) remediable (other than those referred to in clauses 5.8.7, 5.8.8, 5.8.21 or 5.8.22) and such failure is not remedied within fifteen
(15) days after the Agent has given notice thereof to the Builder or the Refund Guarantor, as the case may be (or such longer period as the Agent (acting on the instructions of the Majority Lenders) may specify or agree); or

  
 32 

	5.8.10	Litigation: any litigation, arbitration or administrative action or proceeding is commenced prior to Delivery against the Builder or the Refund Guarantor or any
of their property, undertakings or assets before any court, arbitrator or administrative agency or authority which, if adversely determined, would have in the reasonable opinion of the Agent a Material Adverse
Effectmaterial adverse effect on the financial condition of the Builder or, as the case may be, the Refund Guarantor or their ability to comply with their material obligations
under the Relevant Documents to which they are party unless: 

  

	 	(a)	the Borrower demonstrates in writing to the Agent (who shall act reasonably in considering such matters) to the Agent’s satisfaction, that such litigation,
arbitration or administrative action or proceeding is or may reasonably be considered to be vexatious or frivolous; or 

  

	 	(b)	it is dismissed or irrevocably stayed within thirty (30) days of commencement; 

 

	5.8.11	Legal process: 

  

	 	(a)	any final judgment or order greater than two million Dollars ($2,000,000) made prior to the Delivery Date against the Builder or the Refund Guarantor
is not stayed or complied with within twenty (20) Business Days or a creditor attaches or takes possession of, or a distress, execution, sequestration or other process is levied or enforced upon or sued out against, all or a substantial part of
(in the reasonable opinion of the Agent) the undertakings, assets, rights or revenues prior to delivery of the Builder or the Refund Guarantor and is not discharged within twenty (20) Business Days
and, in each such case above, the event described above has or might reasonably be likely to have a material adverse effect on the financial position of the Builder or, as the case may be,
the Refund Guarantor or their ability to comply with their material obligations under the Relevant Documents to which they are party; or 

  

	 	(b)	any final judgment or order made against any Security Party (other than the Borrower and (following the Delivery Date) the Supervisor) is not stayed or complied with
within twenty (20) Business Days or a creditor attaches or takes possession of, or a distress, execution, sequestration or other process is levied or enforced upon or sued out against, all or substantially all of (in the reasonable opinion of
the Agent) the undertakings, assets, rights or revenues of any Security Party (other than the Borrower and (following the Delivery Date) the Supervisor) and is not discharged within twenty (20) Business Days and, in each such case above, the
event described above has or might reasonably be likely to have a Material Adverse Effect; or 

  

	5.8.12	Insolvency: prior to the Delivery Date, the Builder or the Refund Guarantor is unable or admits inability to pay its debts as they fall due; suspends making
payments on any of its debts or announces an intention to do so; becomes insolvent; has assets the value of which is less than the value of its liabilities; or suffers the declaration of a moratorium in respect of any of its indebtedness; or

  

	5.8.13	Winding up: any corporate action, legal proceedings or other procedure or step is taken for the purpose of winding up prior to Delivery of the Builder or the
Refund Guarantor or an order is made or resolution passed for the winding up, prior to Delivery of the Builder or the Refund Guarantor or a notice is issued convening a meeting for the purpose of passing any such resolution, provided however that,
in the case only of an order for winding-up, the occurrence of such event shall not constitute a mandatory prepayment event if such winding-up has commenced as part of a process of a fully-solvent reorganisation, previously approved by the Agent
acting on the instructions of the Majority Lenders and which shall not have a Material Adverse Effectmaterial adverse effect on the financial condition of the Builder or,
as the case may be, the Refund Guarantor or their ability to comply with their material obligations under the Relevant Documents to which they are party; or 

 

	5.8.14	Administration: any petition is presented, notice given or other step is taken for the purpose of the appointment of an administrator prior to Delivery of the
Builder or the Refund Guarantor or an administration order is made prior to Delivery in relation to the Builder or the Refund Guarantor; or 

  
 33 

	5.8.15	Appointment of receivers and managers: any administrative or other receiver is appointed prior to Delivery of the Builder or the Refund Guarantor or any part of
its assets and/or undertaking or any other steps are taken to enforce any Encumbrance over all or any part of the assets prior to delivery of the Builder or the Refund Guarantor; or 

 

	5.8.16	Compositions: any corporate action, legal proceedings or other procedures or steps are taken, or negotiations commenced prior to Delivery, by the Builder or the
Refund Guarantor or by any of its creditors with a view to the general readjustment or rescheduling of all or a material part of its indebtedness or to proposing any kind of composition, compromise or arrangement involving such company and any of
its creditors; or 

  

	5.8.17	Analogous proceedings: there occurs, prior to Delivery in relation to the Builder or the Refund Guarantor, in any country or territory in which any of them
carries on business or to the jurisdiction of whose courts any part of their assets is subject, any event which, in the reasonable opinion of the Agent, appears in that country or territory to correspond with, or have an effect equivalent or similar
to, any of those mentioned in clauses 10.2.9 to 10.2.15 (inclusive) (other than clause 10.2.10) or prior to Delivery the Builder or the Refund Guarantor otherwise becomes subject, in any such country or territory, to the operation of any law
relating to insolvency, bankruptcy or liquidation; or 

  

	5.8.18	Repudiation: the Supervisor, the Builder or the Refund Guarantor repudiates any Security Document or Project Document to which it is a party or does or causes to
be done any act or thing evidencing an intention to repudiate any such Security Document or the Project Document if the validity or enforceability of any of the Security Documents and the Project Documents (other than the Refund Guarantee) shall at
any time and for any reason be contested by the Supervisor, the Builder or the Refund Guarantor which is a party thereto, or if the Supervisor, the Builder or the Refund Guarantor shall deny that it has any, or any further, liability thereunder; or

  

	5.8.19	Cessation of business: prior to Delivery, the Builder or the Refund Guarantor suspends or ceases to carry on its business; or 

 

	5.8.20	Seizure: all or a material part of the undertaking, assets, rights or revenues of, or shares or other ownership interests, prior to Delivery, in the Builder and
the Refund Guarantor are seized, nationalised, expropriated or compulsorily acquired by or under the authority of any government; or 

  

	5.8.21	Arrest: the Vessel is arrested, confiscated, seized, taken in execution, impounded, forfeited, detained in exercise or purported exercise of any possessory lien
or other claim or otherwise taken from the possession of the Borrower and the Borrower shall fail to procure the release of the Vessel within a period of 30 days thereafter; or 

 

	5.8.22	Supervision Agreement: notice of termination under the Supervision Agreement is served for any reason whatsoever or the Supervision Agreement is varied in any
manner not permitted pursuant to the Security Documents unless (a) in the case of termination the same is replaced with a supervision agreement on substantially the same or other terms acceptable to the Agent or (b) in the case of
variation the same is revised, or amended on terms acceptable to the Agent, and in any such case under (a) or (b) within 30 days. 

  

	5.9	Cessation of KEIC Buyer Credit Policy 

 If, for any reason (other than as referred to in clause 10.2.25), the obligations of KEIC under the KEIC Buyer Credit Policy shall terminate, become unenforceable or otherwise cease to be in full force
and effect and the Borrower has not replaced the KEIC Buyer Credit Policy with similar insurance on terms and conditions satisfactory to the Agent (acting on the instructions of all Lenders in their sole and absolute discretion) forthwith upon
receipt of written notice of such termination, unenforceability or cessation of effectiveness, the Borrower shall prepay the Loan in full together with accrued interest to the date of prepayment and all other sums then due and payable, any portion
of the KEIC premium which is then due and payable and all other sums then due and payable under this Agreement and the other Security Documents or any of them including without limitation any sum payable under the indemnity in clause 15).

  
 34 

	5.10	Prepayment indemnity 

 If
the Borrower shall make a prepayment on a Business Day other than the last day of an Interest Period, it shall pay to the Agent on behalf of the Lenders any amount which is necessary to compensate the Lenders for any Break Costs incurred by the
Agent or any of the Lenders as a result of the prepayment in question but otherwise without penalty or premium, Provided always that the Borrower shall be entitled to payment by the Lenders of any Break Gains while no Event of Default has occurred
which is continuing unremedied or unwaived. 
  

	5.11	Application of prepayments 

Any prepayment in an amount less than the Lender Indebtedness shall be applied pro-rata between the Buyer Credit and the Commercial Loan
and, in the case of the Buyer Credit shall be applied in reducing the then future Repayment Instalments in inverse order of maturity. 
  

	5.12	Effect of Prepayment/Cancellation on Swap Agreements 

 In the event of any prepayment or, as the case may be, cancellation of the Loan, the exposure of the Swap Providers under the Swap Agreements shall, if the Loan Outstandings is less than the aggregate of
the notional amounts of the Swap Agreements, be reduced by an equivalent amount. 
  

	6	Interest 

  

	6.1	Interest Periods 

 The
period during which any Drawing shall be outstanding pursuant to this Agreement shall be divided into consecutive Interest Periods of three (3) Months’ duration or such other duration as may be agreed by the Borrower and the Agent (acting
on the instructions of all Lenders). 
  

	6.2	Beginning and end of Interest Periods 

 The first Interest Period in respect of the first Drawing shall begin on the Drawdown Date of that Drawing and shall end on the last day of the Interest Period. The first Interest Period in respect of
each subsequent Drawing shall begin on the Drawdown Date of that Drawing and end on the last day of the current Interest Period of the Loan. Any subsequent Interest Period in respect of each Drawing shall commence on the day following the last day
of its previous Interest Period and shall end on the last day of its current Interest Period. 
  

	6.3	Interest Periods to meet Repayment Date and Maturity Date 

 If an Interest Period would otherwise end on a date after the next Repayment Date, that Interest Period shall end on the next Repayment Date. If an Interest Period would otherwise end on a date after the
Maturity Date, that Interest Period shall end on the Maturity Date. 
  

	6.4	Interest rate 

 During
each Interest Period, interest shall accrue on the Loan at the rate determined by the Agent to be the aggregate of (a) the relevant Margin and (b) LIBOR determined at 11:00 am (London time) on the second London Business Day prior to the
beginning of the Interest Period. The Agent shall notify the Borrower in writing of the applicable interest rate for the relevant Interest Period on the date of determination. 

  
 35 

	6.5	Accrual and payment of interest 

 During the Facility Period, interest shall accrue from day to day, shall be calculated on the basis of a 360 day year and the actual number of days elapsed (or, in any circumstance where market practice
differs, in accordance with the prevailing market practice) and shall be paid by the Borrower to the Agent on behalf of the Lenders on the last day of each Interest Period and additionally, during any Interest Period exceeding three Months, on the
last day of each successive three Month period after the beginning of that Interest Period. 
  

	6.6	Ending of Interest Periods 

Subject to clause 6.3, if any Interest Period would end on a day which is not a Business Day, that Interest Period shall end on the next
succeeding Business Day (unless the next succeeding Business Day falls in the next calendar Month, in which event the Interest Period in question shall end on the immediately preceding Business Day). 

 

	6.7	Consolidation and division of Loans 

 If two or more Interest Periods: 
  

	 	(a)	relate to Loans; and 

  

	 	(b)	end on the same date, 

  

	 	those	loans will be consolidated into, and treated as, a single Loan on the last day of the Interest Period. 

 

	6.8	Default Rate 

 Each Unpaid
Sum shall, from the date of the non-payment, bear interest up to the date of actual payment (both before and after judgment) at the Default Rate, compounded at such intervals as the Agent shall in its reasonable discretion determine, which interest
shall be payable from time to time by the Borrower to the Agent on behalf of the Lenders on demand. 
  

	6.9	Determinations conclusive 

Each determination of an interest rate made by the Agent in accordance with clause 6 shall (save in the case of manifest error or on any
question of law) be final and conclusive. 
  

	6.10	Mandatory Costs 

 The
Borrower shall reimburse the Agent on demand for any Mandatory Costs relating to the Loan incurred by a Lender as a result of funding its Commitment of the Loan. 
  

	7	Fees 

 The Borrower shall
pay the following fees: 
  

	7.1	Arrangement fee 

 The
Borrower shall pay to the Agent, for the account of the Lenders, arrangement fees in the amounts and at the times agreed in the Arrangement Fee Letter. 

  
 36 

	7.2	Commitment fee 

 The
Borrower shall pay to the Agent: 
  

	7.2.1	(for the account of the Lenders in proportion to their Buyer Credit Commitments) a commitment fee computed at the rate of zero point two five per cent (0.25%) per annum
on the daily undrawn and uncancelled amount of the Buyer Credit Maximum Amount from time to time; and 

  

	7.2.2	for the account of the Lenders (in proportion to their Commercial Loan Commitments) a commitment fee computed at the rate of zero point four five per cent (0.45%) per
annum on the daily undrawn and uncancelled amount of the Commercial Loan Maximum Amount from time to time, 

 in
each case from the date of this Agreement until the earlier to occur of the Drawdown Date in respect of the final Drawing and the Availability Termination Date. The accrued commitment fees are payable in arrears on the last day of each successive
period of three Months from the date of this Agreement and on such Availability Termination Date. 
  

	7.3	Agency fee 

 The Borrower
shall pay to the Agent, the Security Trustee and the KEIC Agent (in each case, for its own account) an agency fee in the amount and at the times agreed in the Agency Fee Letter. 

 

	7.4	Documentation Agency Fee 

The Borrower shall pay to Calyon (for its own account) a documentation agency fee in the amount and at the times agreed in the
Documentation Agency Fee Letter. 
  

	7.5	Account Bank Fee 

 The
Borrower shall pay to the Account Bank (for its own account) an account bank fee in the amount and at the times agreed in the Account Bank Fee Letter. 
  

	7.6	KEIC Insurance Premium 

  

	7.6.1	The Borrower agrees that it shall pay to the KEIC Agent, on the date of the first Drawing under the Commercial Loan, an amount equal to the KEIC Insurance Premium to be
paid by the KEIC Agent to KEIC. 

  

	7.6.2	The Borrower agrees that its obligation to make the payment described in clause 7.6.1 above or any part of it shall be an absolute obligation and without limitation,
shall not be affected by any failure to draw down funds under this Agreement or the prepayment or acceleration of any Loan. Neither the KEIC Insurance Premium nor any part of it shall be refundable to the Borrower under any circumstances. If and to
the extent that the KEIC Agent subsequently receives from KEIC a refund of the KEIC Insurance Premium or any part thereof, the KEIC Agent shall account to the Agent for the amount of the refund received by the KEIC Agent less any costs and expenses
suffered or incurred by the KEIC Agent in recovering and/or transferring such refunded amount to the Agent for application by the Agent in prepayment of the Commercial Loan Outstandings in whole or in part. 

 

	7.6.3	Without prejudice to the Borrower’s obligations under clauses 7.6.1 and 7.6.2, the Lender Finance Parties and the Borrower acknowledge that the first Drawdown
under the Commercial Loan shall be utilised, inter alia, to enable the Borrower to satisfy its obligation under clause 7.6.1. The Borrower instructs the Agent, in accordance with clause 2.3.9, to pay an amount equal to the KEIC Insurance Premium
from the first Drawing under the Commercial Loan to the KEIC Agent. Upon receipt by the KEIC Agent of such amount, the Borrower shall have satisfied its obligation under clause 7.6.1. 

  
 37 

	8	Security, Accounts and Application of Moneys 

  

	8.1	Security Documents 

 As
security for the repayment of the Indebtedness, the Borrower shall, subject to the terms and conditions of this Agreement, execute and deliver to the Security Trustee or cause to be executed and delivered to the Security Trustee the following
documents in such forms and containing such terms and conditions as the Security Trustee shall require: 
  

	8.1.1	first priority deed of assignment of the Building Contract and Refund Guarantee; 

 

	8.1.2	a first priority statutory mortgage over the Vessel together with a collateral deed of covenants; 

 

	8.1.3	a first priority tripartite deed of assignment of the Insurances, Earnings and Requisition Compensation of the Vessel from the Borrower and the Manager;

  

	8.1.4	first priority deed of charge over each of: 

  

	 	(a)	the Revenue Account; 

  

	 	(b)	the Dry Docking Reserve Account; 

  

	 	(c)	the Retention Account; 

  

	 	(d)	the Debt Service Reserve Account; and 

  

	 	(e)	the Dividend Lock-up Account; 

  

	8.1.5	first priority deed of assignment over each of: 

  

	 	(a)	the Supervision Agreement; 

  

	 	(b)	the Time Charter; 

  

	 	(c)	the Depot Spares Sharing Agreement; 

  

	 	(d)	the Management Agreement and the Sub Management Agreement; 

 

	 	(e)	the Swap Agreements; 

  

	 	(f)	the Tripartite Agreement; 

  

	8.1.6	a first priority charge over the entire issued share capital of the Borrower; 

 

	8.1.7	the Letter of Sponsors Undertakings; and 

  

	8.1.8	the Manager’s Undertaking. 

  

	8.2	Accounts 

  

	8.2.1	General 

 The Borrower
undertakes with each of the Lenders, the Agent, the Account Bank and the Security Trustee that it will: 
  

	 	(a)	on or before the first Drawing open the Accounts with the Account Bank; and 

 

	 	(b)	procure that all moneys payable to the Borrower including, without limitation, in respect of the Earnings of the Vessel (including all hire and early termination fees
payable to it under the Time Charter, all payments made under any letters of credit or insurance policies issued in favour of the Borrower pursuant to the Time Charter and pursuant to the Insurances but excluding any Borrower Priority Payments)
shall, unless and until the Agent directs to the contrary pursuant to the Security Documents be paid to the Revenue Account; 

  
 38 

	8.3	Revenue Account: withdrawals 

 Unless the Agent otherwise agrees in writing (acting on the instructions of the Majority Lenders) the Borrower shall not be entitled to withdraw any moneys from the Revenue Account at any time other than
for the following purposes and in the following order of priority: 
  

	8.3.1	to pay the proper and reasonable operating expenses (including costs of insuring, repairing and maintaining the Vessel) of the Vessel, including amounts properly due to
the Manager under the Management Agreement, the Supervisors under the Supervision Agreement and Mitsui under the Corporate Management Agreement, the proper and reasonable expenses of administering the affairs of the Borrower and the Taxes of the
Borrower; 

  

	8.3.2	 to transfer to the Dry Docking Reserve Account, first time three (3) months after the Delivery Date and at three (3) Monthly intervals
thereafter up to and including the date upon which the Vessel completes each such scheduled dry docking, an amount equal to
1/
20 of the total Dry Docking Reserve Account Payments in respect of such next scheduled dry docking;

  

	8.3.3	to transfer to the Retention Account on the next following Retention Date all or part of the Retention Amount for such Retention Date; 

 

	8.3.4	to pay any other amounts payable under the Security Documents (including payments to the Swap Providers under any of the Swap Agreements and in case of partial payments
the Swap Providers will be paid pro-rata); 

  

	8.3.5	to transfer to the Debt Service Reserve Account all or part of the DSRA Amount if any remains unpaid; and 

 

	8.3.6	to transfer any surplus to the Distribution Account unless at any relevant time a Dividend Restriction Event has occurred which is continuing unremedied or unwaived in
which case any surplus shall be transferred to the Dividend Lock-Up Account, Provided that where such Dividend Restriction Event has ceased to be continuing and in circumstances where there is no Potential Event of Default or Event of Default which
is continuing unremedied or unwaived such surplus may be transferred from the Dividend Lock-Up Account to the Distribution Account. 

  

	8.4	Dry Docking Reserve Account: withdrawals 

  

	8.4.1	Unless the Agent otherwise agrees in writing, the Borrower shall not be entitled to withdraw any moneys from the Dry Docking Reserve Account other than to meet
dry-docking costs which shall have been advised to and the aggregate amount of which shall have been approved by the Agent (acting reasonably and without delay) and in respect of which the Borrower shall have provided to the Agent reasonably
satisfactory documentary evidence that such dry-docking costs have been incurred or will be incurred provided however that the Borrower shall be entitled to request the Agent by notice in writing to release any balance standing to the credit of the
Dry Docking Reserve Account, after reimbursement to the Borrower from the Dry Docking Reserve Account of all dry docking costs and expenses paid by it, immediately following completion of a scheduled dry docking of the Vessel and the Agent shall
transfer any such balance to the Distribution Account provided that the Agent is satisfied that: 

  

	 	(a)	all amounts then required to be paid to the Retention Account have been so paid; 

 

	 	(b)	the DSRA Amount has been paid in full and is standing to the credit of the Debt Service Reserve Account or has been replaced by the DSRA Letter of Credit; and

  

	 	(c)	at such time no Dividend Restriction Event has occurred which is continuing unremedied or unwaived in which case any such balance shall be transferred to and retained
in the Dividend Lock-up Account. 

  
 39 

	8.5	Debt Service Reserve Account: withdrawals 

 Without prejudice to the rights of the Lender Finance Parties under clause 9.1.18 (particularly, without limitation, the right of the Lender Finance Parties to use the amounts standing to the credit of
the Debt Service Reserve Account to service any Loan repayments which have become due), the Borrower shall not be entitled to withdraw any moneys from the Debt Service Reserve Account at any time from the date of this Agreement and so long as moneys
are owing under the Security Documents save that, unless and until a Potential Event of Default or an Event of Default shall occur (which is continuing unremedied or unwaived) and the Agent shall direct to the contrary in accordance with the
Security Documents, the Borrower may withdraw moneys from the Debt Service Reserve Account provided that a DSRA Letter of Credit is issued in an amount sufficient to constitute security at least of an equivalent Dollar for Dollar value as the amount
withdrawn (and subject to the other provisions of this Agreement in relation to the DSRA Letter of Credit). In the event that the credit rating of an L/C Issuer falls below the Minimum Credit Rating applicable to it as described in clause 9.1.20,
the Borrower shall immediately credit the Debt Service Reserve Account with an amount equal to the amount covered by the DSRA Letter of Credit provided by such L/C Issuer until the conditions set out in clauses 9.1.18 and 9.1.20 have been satisfied
in full, and clause 9.1.18 shall apply as if the reference in such clause to “the date falling twenty seven (27) months after the Delivery Date” were a reference to the date the Borrower so credited the Debt Service Reserve Account
and, to the extent that the Borrower is in breach of its obligations to so credit the Debt Service Reserve Account, the Lender Finance Parties shall immediately be entitled in their absolute discretion to make a demand under the DSRA Letter of
Credit for the full amount in respect of which such DSRA Letter of Credit has issued. 
  

	8.6	Dividend Lock-Up Account: withdrawals 

 The Borrower shall not be entitled to withdraw any moneys from the Dividend Lock-Up Account except if there are no Dividend Restriction Events continuing. 

 

	8.7	Distribution Account: withdrawals 

 The Borrower shall be entitled to withdraw and freely apply all moneys standing to the credit of the Distribution Account from time to time. 

 

	8.8	Retention Account: credits and withdrawals 

  

	8.8.1	Unless and until there shall occur an Event of Default which is continuing unremedied or unwaived (whereupon the provisions of clause 8.12 shall apply and subject to
the Security Documents), all Retention Amounts credited to the Retention Account together with interest from time to time accruing or at any time accrued thereon shall be applied by the Account Bank (and the Borrower undertakes to give an
irrevocable and unconditional instruction to the Account Bank so to apply the same) in the following manner: 

  

	 	(a)	upon each Repayment Date in or towards payment to (i) the Agent of the instalment then falling due for repayment and the amount of interest then due and
(ii) to the Swap Providers of amounts then falling due under the Swap Agreements (if any). Each such application by the Account Bank shall constitute a payment in or towards satisfaction of the Borrower’s corresponding payment obligations
under this Agreement and the Swap Agreements but shall be strictly without prejudice to the obligations of the Borrower to make any such payment to the extent that the aforesaid application by the Account Bank is insufficient to meet the same; and

  

	 	(b)	following any application by the Account Bank pursuant to sub-clause (a) above, in transfer to the Revenue Account of any moneys standing to the credit of the
Retention Account. 

  
 40 

	8.8.2	Unless the Agent otherwise agrees in writing and subject to clause 8.8.1, the Borrower shall not be entitled to withdraw any moneys from the Retention Account at any
time from the date of this Agreement and so long as any moneys are owing under the Security Documents. 

  

	8.9	Application of accounts 

At any time after the Agent has exercised its rights pursuant to clause 10.1, the Agent may, without notice to the Borrower but subject to
the terms of the Security Documents, instruct the Account Banks to apply all moneys then standing to the credit of the Accounts (other than the Distribution Account) (together with interest from time to time accruing or accrued thereon) in payment
to the Security Trustee and the Security Trustee shall apply the same in or towards satisfaction of any sums due to the Agent, the Security Trustee, the KEIC Agent, the Swap Providers and the Lenders under the Security Documents in the manner
specified in the Intercreditor Deed. 
  

	8.10	Interest and surpluses 

  

	8.10.1	Each of the Accounts shall bear interest upon the Account Bank’s standard terms for Dollar deposits in similar amounts and for periods comparable for which such
balances appear to the Account Bank likely to remain on the relevant Account and any interest credited to the Accounts (other than the Distribution Account) shall, unless and until an Event of Default (which is continuing unremedied or unwaived)
shall occur in which case, subject to the Security Documents, the provisions of clause 8.9 shall apply, be paid to the Revenue Account. 

  

	8.11	Charging of accounts 

 The
Accounts (other than the Distribution Account) and all amounts from time to time standing to the credit thereof shall be subject to the security constituted and the rights conferred by the relevant Security Documents. 

 

	8.12	General application of moneys 

 Whilst an Event of Default is continuing unremedied or unwaived the Borrower irrevocably authorises the Agent and the Security Trustee to apply all sums which either of them may receive: 

 

	8.12.1	pursuant to a sale or other disposition of the Vessel or any right, title or interest in the Vessel; or 

 

	8.12.2	by way of payment of any sum in respect of the Insurances, Earnings, or Requisition Compensation; or 

 

	8.12.3	otherwise arising under or in connection with any Security Document, 

 in accordance with the terms of the Intercreditor Deed. 
  

	9	Covenants 

 The Borrower
covenants with the Lender Finance Parties in the following terms.  
  

	9.1	General 

 The Borrower
undertakes with the Lender Finance Parties that, from the date of this Agreement and so long as any moneys are owing under any of the Security Documents and while all or any part of the Commitments remains outstanding, it will: 

 

	9.1.1	Notice of Default 

  

	 	(a)	promptly inform the Agent in writing of any occurrence of which it becomes aware which might materially and adversely affect the ability of any Security Party, the Time
Charterer, the Builder or the Refund Guarantor to perform its obligations under any of the Relevant Documents to which it is a party and, without limiting the generality of the foregoing, will inform the Agent of any Event of Default or Potential
Event of Default or Mandatory Prepayment Event forthwith upon becoming aware thereof and will from time to time, if so requested by the Agent, confirm to the Agent in writing that, save as otherwise stated in such confirmation, no Event of Default
or Potential Event of Default has occurred and is continuing unremedied or unwaived; 

  

  
 41 

	 	(b)	promptly inform the Agent of any occurrence of which it becomes aware which might materially adversely effect the ability or rights of the Borrower to make any claims
under any of the Refund Guarantee or which might reduce or release any of the obligations of any Refund Guarantor under any of its Refund Guarantee; 

  

	9.1.2	Consents and licences 

obtain or cause to be obtained, maintain in full force and effect and comply in all material respects with the conditions and restrictions
(if any) imposed in, or in connection with, every consent, Authorisation, licence or approval of governmental or public bodies or authorities or courts, the failure of which has or might be likely to have a Material Adverse Effect, and do, or cause
to be done, all other acts and things which may from time to time be necessary under applicable law for the continued due performance of all the obligations of the Security Parties under each of the Security Documents; 

 

	9.1.3	Use of proceeds 

 use the
Loan exclusively for the purpose specified in the Recitals and/or clause 2.3.4; 
  

	9.1.4	Pari passu 

 ensure that
its obligations under this Agreement and the other Security Documents shall, without prejudice to the security intended to be created by the Security Documents, at all times rank at least pari passu with all its other present and future unsecured
and unsubordinated indebtedness with the exception of any obligations which are mandatorily preferred by law and not by contract; 
  

	9.1.5	Financial statements 

prepare financial statements of the Borrower in accordance with GAAP in respect of each financial year and cause the same to be reported
on by its auditors and prepare semi-annual (i.e two (2) sets of accounts to be provided each year) unaudited accounts (without accounting notes) and deliver as many copies of the same and copies of each Sponsor’s annual audited financial
statements as the Agent may reasonably require not later than one hundred and twenty (120) days (in the case of the Borrower’s audited financial statements), sixty (60) days (in the case of semi-annual unaudited accounts) or one
hundred and eighty (180) days (in the case of the Sponsors’ annual audited financial statements), in each case after the end of the financial period to which they relate; 

 

	9.1.6	Information 

 deliver to
the Agent or procure that there is delivered to the Agent: 
  

	 	(a)	at the time of issue thereof, as many copies as the Agent may reasonably require of written communications made by any Security Party to its shareholders or creditors
generally which may reasonably be considered material in the context of this Agreement (other than copies of reports or other notices, statements or circulars sent or delivered to the
Borrower Shareholders by the Borrower, which shall be sent to the Security Trustee pursuant to clause 6.2.11 of the Share Charges); 

  
 42 

	 	(b)	from time to time as the Agent and/or KEIC may reasonably require: 

  

	 	(i)	such financial or other information concerning any Security Party and its affairs which may reasonably be
considered material in the context of this Agreement; 

  

	 	(ii)	such information relating to the progress of construction of the Vessel, or otherwise in relation to the construction of the Vessel and performance by the Builder of
its obligations under the Building Contract; and 

  

	 	(iii)	such information in connection with the operation, position and condition of the Vessel; 

 

	 	(c)	at the time of each such communication, copies of all material written communications between the Borrower or any other Security Party and: 

 

	 	(i)	the approved brokers; and 

  

	 	(ii)	the approved protection and indemnity and/or war risks associations; and 

  

	 	(iii)	the approved insurance companies and/or underwriters; 

  

	 	    	which relate directly or indirectly to: 

  

	 	(A)	the Vessel and the obligations of the Borrower or any other Security Party relating to the Insurances including, without limitation, all requisite declarations and
payments of additional premiums or calls and all communication relating to non-payment of premiums or calls and cancellation of any of the Insurances or relating to the imposition of any new or modified condition, warranty, exclusion or
qualification or the material alteration of the Insurances; and 

  

	 	(B)	any credit arrangements made between the Borrower or any other Security Party and any of the persons referred to in clauses 9.5.7(a) to 9.5.7(c) relating wholly or
partly to the effecting or maintenance of the Insurances. 

  

	9.1.7	Vessel Annual Operating Budget 

 prior to the commencement of each budget year, submit to the Agent the annual operating budget of the Vessel for such budget year for approval by the Agent (acting on the instruction of the Majority
Lenders and such approval not to be unreasonably withheld or delayed); 
  

	9.1.8	Obligations under Security Documents 

 duly and punctually perform each of the obligations expressed to be assumed by it under the Security Documents to which it is a party; 

 

	9.1.9	Certificate of Financial Responsibility 

 obtain and maintain a certificate of financial responsibility in relation to the Vessel if it is to call at the United States of America; 

 

	9.1.10	ISM and ISPS Compliance 

ensure that the relevant Company and any Environmental Affiliate complies in all material respects with the ISM Code and the ISPS Code or
any replacements thereof and in particular (without prejudice to the generality of the foregoing) shall ensure that the Company holds (i) a valid and current Document of Compliance issued pursuant to the ISM Code, (ii) a valid and current
Safety Management Certificate issued in respect of the Vessel pursuant to the ISM Code, and (iii) an ISSC in respect of the Vessel, and the Borrower shall promptly, upon request, supply the Agent with copies of the same; 

  
 43 

	9.1.11	Compliance with Applicable Laws 

 comply with all applicable laws to which it may be subject from time to time; 
  

	9.1.12	Further Assurance 

 at its
own expense, promptly take all such action as the Agent may reasonably require for the purpose of perfecting or protecting any Lender Finance Party’s rights with respect to the security created or evidenced (or intended to be created or
evidenced) by the Security Documents; 
  

	9.1.13	“Know your customer” Checks 

 if: 
  

	 	(a)	the introduction of or any change in (or in the interpretation, administration or application of) any law or regulation made after the date of this Agreement;

  

	 	(b)	any change in the status of the Borrower after the date of this Agreement; or 

 

	 	(c)	a proposed assignment or transfer by a Lender of any of its rights and obligations under this Agreement to a party that is not a Lender prior to such assignment or
transfer, 

 obliges the Agent or any Lender (or, in the case of (c) above, any prospective new Lender) to
comply with “know your customer” or similar identification procedures in circumstances where the necessary information is not already available to it, promptly upon the request of the Agent or any Lender supply, or procure the supply of,
such documentation and other evidence as is reasonably requested by the Agent (for itself or on behalf of any Lender) or any Lender for itself (or, in the case of (c) above, on behalf of any prospective new Lender) in order for the Agent or
that Lender (or, in the case of (c) above, any prospective new Lender) to carry out and be satisfied it has complied with all necessary “know your customer” or other similar checks under all applicable laws and regulations pursuant to
the transactions contemplated in the Relevant Documents, Provided that, the obligations set forth in this clause shall not apply to information in respect of Angola LNG, the Angola LNG Project (in any respect), the Time Charterer, the Builder, the
Refund Guarantor or the L/C Issuer unless such information is required by Law; 
  

	9.1.14	Management Fees 

 pay all
amounts due to the Manager under the Management Agreement when the same become due and payable; 
  

	9.1.15	Time Charters 

 ensure
that: 
  

	 	(a)	the Vessel is constructed pursuant to the Building Contract so that on the Delivery Date the Vessel is accepted by the Time Charterer under the Time Charter;

  

	 	(b)	from the Delivery Date and throughout the Facility Period: 

  

	 	(i)	subject to clauses 5.8.3 and 5.8.4, the Vessel shall be chartered to the Time Charterer under the Time Charter or (subject to clause 9.2.18) a bareboat charter unless
the Agent, acting on the instruction of all the Lenders (acting reasonably and without delay) otherwise agrees; 

  

	 	(ii)	no amendments are made to (aa) the Time Charter (other than in respect of purely technical and/or operational matters which shall have
no material adverse financial effect upon the Borrower, no adverse effect upon the security rights of the Agent, the
Security Trustee, the KEIC Agent, the Lenders or the Swap Providers, which shall not have the effect of reducing the rate of hire payable under the Time Charter or amending the dates on which such hire is payable or
reducing the period of the contractTime
Charter itself and which shall in any event be promptly notified to the Agent) or (bb) to any letters of credit or insurance policies to be issued under the Time Charter, in each case without the consent of the Agent (such consent not to be
unreasonably withheld or delayed); and 

  

	 	(iii)	all licenses, consents and Authorisations necessary to permit the proper and lawful operation of the Vessel pursuant to the Time Charter in any Relevant Jurisdiction to
which the Vessel may be ordered or trade are complied with and ensure that each such licence, consent and Authorisation has been properly and validly obtained; and 

  

  
 44 

	 	(c)	upon the occurrence of any force majeure as set out in the Time Charter or any incident or other occurrence of which it is aware which may reasonably be expected to
become a force majeure upon the giving of notice or lapse of time the Borrower shall forthwith advise the Agent of such force majeure or incident or occurrence which may become a force majeure and keep the Agent up to date in respect of all matters
and/or developments in respect of such force majeure and/or incident and/or occurrence; 

  

	9.1.16	Use of Ancillary Cost Advances 

 procure that each Ancillary Cost Advance and the proceeds thereof are used only for the purpose of paying and discharging Ancillary Costs, reimbursing Ancillary Costs already paid by the Borrower, as
contemplated by clause 2.3.4 and paying the KEIC Insurance Premium and for no other purpose; 
  

	9.1.17	Management 

 ensure that
following Delivery the Vessel is managed throughout the Facility Period by the Manager pursuant to the Management Agreement or such party as may replace the Manager in accordance with clause 9.2.18 and 10.3 of this Agreement; 

 

	9.1.18	DSRA Letter of Credit/Debt Service Reserve Account 

  

	 	(a)	on or before the date falling twenty seven (27) Months after the Delivery Date procure that as a result of either: 

 

	 	(i)	the issue of the DSRA Letter of Credit; and/or 

  

	 	(ii)	sums standing to the credit of the Debt Service Reserve Account, 

 the aggregate of the amounts standing to the credit of the Debt Service Reserve Account and/or the amount of the DSRA Letter of Credit shall, subject to clause (b) below, be equal to or not less than
such amount as the Agent shall determine to be 6 Months’ principal and interest repayments under this Agreement (the “DSRA Amount”) Provided Always that: 

 

	 	(A)	the sum standing to the credit of the Debt Service Reserve Account shall, in accordance with and subject to the provisions of the Security Documents, be freely
available to the Lender Finance Parties (a) upon the acceleration of the Loan after the occurrence of an Event of Default which is continuing unremedied or unwaived and (b) to service any Loan repayments which have become due in the
circumstances set out in clause 9.1.18(b) below; and 

  

	 	(B)	 in relation to any DSRA Letter of Credit the Borrower shall provide the Agent with such evidence as the Agent may reasonably require to satisfy the
Agent that such DSRA Letter of Credit has been duly and Validly and correctly issued (including, without limitation, a signing authority authorising
the L/C Issuer to provide the DSRA Letter of Credit and a legal opinion from counsel in the jurisdiction of the L/C Issuer in each case in form and substance satisfactory to the Agent),

  
 45 

	 	
and in the event that the Borrower elects to issue the DSRA Letter of Credit the Borrower shall ensure that (A) all sums payable under such DSRA Letter of Credit shall, in accordance with
and subject to the provisions of the Security Documents, be freely available to the Lender Finance Parties (a) upon the acceleration of the Loan after the occurrence of an Event of Default which is continuing, (b) to service any Loan
repayments which have become due in the circumstances set out in clause (b) below and where there are insufficient amounts standing to the credit of the Debt Service Reserve Account to service such Loan repayments and (c) in the
circumstances set out in clause 8.5 and (B) any DSRA Letter of Credit shall be renewed or replaced for a period being not less than 12 Months to such value as may be required to satisfy the provisions of this clause 9.1.18 not later than 30
days prior to the scheduled date of its expiry. If the Borrower fails to so renew or replace the DSRA Letter of Credit, the Borrower agrees that the Security Trustee shall have the right upon written notice to the Borrower to draw the entire amount
available under such DSRA Letter of Credit and deposit such amount in the Debt Service Reserve Account for application in accordance with the provisions of this Agreement. For the avoidance of doubt, if the Security Trustee shall at any time
drawdown the entire amount available under any DSRA Letter of Credit and deposit the same in the Debt Service Reserve Account, such drawdown and deposit shall be deemed to remedy any Event of Default which shall have arisen as a result of the
Borrower’s failure to renew or replace such DSRA Letter of Credit for a period of not less than 12 Months in accordance with the provisions of this clause 9.1.18; 

 

	 	(b)	Notwithstanding the provisions of clauses 8.5 and 9.1.18(a) above, the Lender Finance Parties shall, in their absolute discretion, be entitled to:

  

	 	(i)	use the sum standing to the credit of the Debt Service Reserve Account from time to time; and/or 

 

	 	(ii)	make a demand under the DSRA Letter of Credit, 

 in each case to satisfy the Borrower’s obligation to pay a Repayment Instalment or Repayment Instalments which have become due and such sums and/or (as the case may be) the DSRA Letter of Credit
shall be freely available to the Lender Finance Parties for these purposes. 
 In the event that the Lender Finance Parties
elect to exercise their rights under this clause 9.1.18(b) the Borrower shall have sixty (60) days to restore the aggregate of the amounts standing to the credit of the Debt Service Reserve Account and/or the amount of the DSRA Letter of Credit
to an amount equal to the DSRA Amount. 
  

	9.1.19	Financial covenants 

provide the Agent at the same time it provides its audited financial statements and unaudited semi-annual accounts in accordance with
clause 9.1.5 with a Compliance Certificate signed by an authorised officer of the Borrower (i) that the average DSCR in respect of the immediately preceding four (4) financial quarters is equal to or above 1:10x, (ii) that the average
DSCR in respect of the immediately preceding two (2) financial quarters is equal to or above 1.06x and (iii) its Leverage Ratio for the immediately preceding four (4) financial quarters does not exceed 4:1. Such Compliance Certificate
shall also attach full details of how the said DSCR and Leverage Ratio was calculated; 
  

	9.1.20	Minimum Credit Rating 

 in
the event that the credit rating of an L/C Issuer falls below the Minimum Credit Rating applicable to it, then the Borrower shall immediately (a) inform the Agent and (b) credit the Debt Service Reserve Account in accordance with clause
8.5; 

  
 46 

	9.1.21	Supervision Agreement 

  

	 	(a)	ensure that throughout the period prior to Delivery of the Vessel the construction of the Vessel is supervised by the Supervisor pursuant to the Supervision Agreement
and will not agree to any material variation of the Supervision Agreement or any sum payable by the Borrower to the Supervisor under the Supervision Agreement; and 

 

	 	(b)	at all times enforce all of its rights under the Supervision Agreement; 

  

	9.1.22	Developments regarding the Angola LNG Project 

 as soon as reasonably practicable but subject to any confidentiality restrictions and limitations in the Time Charter and any other agreements of the Borrower, notify the Agent of any material
developments notified to it by the Time Charterer regarding the Angola LNG Project or the Time Charterer, including, but not limited to, decisions regarding the rollover of the Gas Supply Agreement, the identity of the LNG gas buyers and any force
majeure event under the Gas Supply Agreement, the LNG Agreement, the Time Charter or the Gas Sales and Purchase Agreement, Provided always that (subject to clause 9.1.15) the Borrower shall not have or be deemed to have any obligation under this
Agreement or any Security Documents to request any information from the Time Charterer or any of its members, shareholders, directors, officers, employees or representatives regarding the Angola LNG Project or the Time Charterer; 

 

	9.1.23	Registration 

 ensure that
the Vessel shall on and from the Delivery Date be registered under the laws of the flag of the Flag State (or the flag of such other state as the Agent may consent to in writing, acting on the instruction of the Majority Lenders and KEIC);

  

	9.1.24	Project Co-ordination Agreement 

  

	 	1.1.1	Prior to the first Drawing, procure the execution of the Project Co-ordination Agreement in a form and substance acceptable in all respects to KEIC and to the Agent
acting on the instructions of the Majority Lenders. 

  

	9.2	Negative undertakings 

The Borrower undertakes with the Agent that, from the date of this Agreement and so long as any moneys are owing under the Security
Documents and while all or any part of the Commitments remain outstanding, it will not without the prior written consent of the Agent: 
  

	9.2.1	Negative pledge 

 permit
any Encumbrance (other than a Permitted Encumbrance) to subsist, arise or be created or extended over all or any part of its present or future undertakings, assets, rights or revenues (including, without limitation to the generality of the
foregoing, over the Vessel, the Time Charter, Earnings, Insurances and/or Accounts) to secure or prefer any present or future indebtedness or other liability or obligation of it or any other person; 

 

	9.2.2	No merger 

 without the
prior written consent of the Agent acting on the instructions of all Lenders merge or consolidate with any other person unless such merger or consolidation does not result in a Change of Control; 

 

	9.2.3	Disposals 

 Subject to the
rights of the Time Charterer under the Time Charter; 
  

	 	(a)	sell, transfer, abandon, lend or otherwise dispose of or cease to exercise direct control over any part (being either alone or when aggregated with all other disposals
falling to be taken into account pursuant to this clause 9.2.3 material in the opinion of the Agent (acting reasonably and without unreasonable delay) in relation to the combined undertakings, assets, rights and revenues of the Borrower) of its
present or future undertaking, assets, rights or revenues (otherwise than by transfers, sales or disposals for full consideration in the ordinary course of trading or otherwise in accordance with the Depot Spares Sharing Agreement) whether by one or
a series of transactions related or not; or 

  
 47 

	 	(b)	sell, transfer, abandon, lease or otherwise dispose of or part with possession of the Vessel other than pursuant to clause 9.6.14 or with the prior written consent of
the Agent acting on the instructions of the Majority Lenders and KEIC; 

  

	9.2.4	Other business 

 undertake
any business other than the ownership, financing (including the refinancing of the Vessel at the Maturity Date), maintenance and operation of the Vessel, the Depot Spare Parts, the chartering of the Vessel for the Time Charterer and making
Authorised Investments as permitted by the Security Documents; 
  

	9.2.5	Acquisitions 

 acquire any
further assets other than Authorised Investments, the Vessel, the Depot Spare Parts and other assets and rights arising under contracts entered into by it in the ordinary course of its business of owning, operating, maintaining and chartering the
Vessel or in refinancing the Vessel at the Maturity Date, provided always that the Loan Outstandings shall be repaid in full from the proceeds of such refinancing of the Vessel at the Maturity Date; 

 

	9.2.6	Other obligations 

 incur
any obligations except for obligations arising under the Relevant Documents to which it is a party or contracts entered into by it in the ordinary course of its business of owning, operating, maintaining and chartering the Vessel; 

 

	9.2.7	Guarantees 

 issue any
guarantees or indemnities or otherwise become directly or contingently liable for the obligations of any person, firm, or corporation except for guarantees or indemnities from time to time required in the ordinary course by any protection and
indemnity or war risks association with which the Vessel is entered, guarantees required to procure the release of the Vessel from any arrest, detention, attachment or levy or guarantees or undertakings required for the salvage of the Vessel and
except pursuant to the Security Documents; 
  

	9.2.8	Loans 

 make any loans or
grant any credit (save for normal trade credit in the ordinary course of business) to any person or agree to do so; 
  

	9.2.9	No borrowing 

 incur any
Financial Indebtedness or undertake any material capital commitment except: 
  

	 	(a)	for trade credit in the ordinary course of business and Financial Indebtedness pursuant to the Security Documents (including the Swap Agreements); and

  

	 	(b)	the Minimum Borrower Shareholders’ Equity and Additional Shareholders’ Equity contributed by way of subordinated debt and subordinated to the amounts due and
owing to the Agent, the Security Trustee, the KEIC Agent, the Swap Providers and the Lenders under the Security Documents; 

  
 48 

	9.2.10	Repayment of borrowings 

repay the principal of, or pay interest on or any other sum in connection with any of its Financial Indebtedness except such Financial
Indebtedness as is permitted by the Security Documents or with the prior written consent of the Agent; 
  

	9.2.11	Sureties 

 permit any
Financial Indebtedness of the Borrower to any person (other than the Lenders and/or the Agent and/or the Security Trustee and/or the Swap Providers under the Swap Agreements to be guaranteed by any person (save for guarantees or indemnities from
time to time required in the ordinary course by any protection and indemnity or war risks association with which the Vessel is entered, guarantees required to procure the release of the Vessel from any arrest, detention, attachment or levy or
guarantees or undertakings required for the salvage of the Vessel; 
  

	9.2.12	Share capital and distribution 

 purchase or otherwise acquire for value any shares of its capital or declare or pay any dividends or distribute any of its present or future assets, undertakings, rights or revenues to any of its
shareholders, save that the Borrower shall be permitted to declare or pay dividends provided that no Event of Default or Dividend Restriction Event has occurred and is continuing unremedied or unwaived or would occur as a result; 

 

	9.2.13	Subsidiaries 

 form or
acquire any Subsidiaries; 
  

	9.2.14	Constitutional documents 

agree to any material change of its memoranda and articles of association or other constitutional documents; 

 

	9.2.15	Project Documents 

subject to clause 9.1.15(b)(ii) (which provides, for the avoidance of doubt,
that amendments to the Time Charter in respect of technical and/or operational matters which shall have no material adverse financial effect upon the Borrower, no adverse effect upon the security rights of the Agent, the Security Trustee, the KEIC
Agent, the Lenders or the Swap Providers, which shall not have the effect of reducing the rate of hire payable under the Time Charter or amending the dates on which such hire is payable or reducing the period of the Time Charter itself and which
shall in any event be promptly notified to the Agent, may be made or permitted by the Borrower without the consent of the Agent), materially amend, modify or waive any provision of the Project Documents to which it is a party or agree to
materially amend, modify or waive any provision of the Project Documents to which it is not a party but which requires its consent without the prior written consent of the Agent (acting on the instructions of the Majority Lenders); 

 

	9.2.16	Borrower’s other documents 

 enter in to any other material documents or agreements relating to the Angola LNG Project (other than such documents or agreements contemplated by the Time Charter) (such other material documents or
agreements, “Borrower’s Other Documents”) and, if the Agent shall consent to the Borrower’s entry into any Borrower’s Other Documents (which consent shall not be unreasonably withheld or delayed but the giving of
which consent may be subject to the Borrower assigning or otherwise charging all its rights, title, benefits and interests under such Borrower’s Other Documents in favour of the Security Trustee as security for the Loan and any other sums
payable under the other Security Documents), the Borrower shall not agree to any material change to the Borrower’s Other Documents without the prior written consent of the Agent (which consent shall not be unreasonably withheld or delayed);

  
 49 

	9.2.17	Ownership of Borrower 

permit any change in the shareholders or their respective (direct or indirect) shareholdings in the Borrower as at the date hereof being:

  

	 	(i)	Mitsui - 34%; 

  

	 	(ii)	NYK - 33%; and 

  

	 	(iii)	Teekay 33%. 

 Provided however
that (a) on Delivery, Teekay or its Wholly-Owned Subsidiary shallmay, subject to the Agent having
confirmed to Teekay in writing (not to be unreasonably delayed) that it is satisfied, acting reasonably that no material adverse effect on Teekay LNG’s consolidated financial position or Teekay LNG’s ability to comply with its material
obligations under any of the Security Documents has occurred and is continuing with respect to Teekay LNG, transfer all of its shares in the Borrower to Teekay LNG or its Wholly-Owned Subsidiary and Teekay LNG or its Wholly-Owned Subsidiary (as
applicable) shall become a “Borrower Shareholder” in place of Teekay or its Wholly-Owned Subsidiary; (b) any of the Borrower Shareholders may at any time but subject always to the requirements of paragraph (c) below,
transfer all or part of its shareholding in the Borrower to:- 
  

	 	(aa)	a Qualifying Entity, provided that such Qualifying Entity accedes to the Security Documents as a Sponsor and a Borrower Shareholder in respect of its proportionate
interest in the Borrower; 

  

	 	(bb)	a Wholly-Owned Subsidiary of any Qualifying Entity provided that, (a) such Wholly-Owned Subsidiary accedes to the Security Documents as a Borrower Shareholder in
respect of its proportionate ownership interest in the Borrower, and (b) the Qualifying Entity accedes to the Security Documents as a Sponsor in respect of its proportionate indirect ownership interest in the Borrower; 

 

	 	(cc)	a Sponsor, another Borrower Shareholder or to an Affiliate of a Sponsor or a Borrower Shareholder, provided that, such Affiliate or Sponsor (as the case maybe) accedes
to the Security Documents as a Borrower Shareholder in respect of its proportionate ownership interest in the Borrower; or 

  

	 	(dd)	any other person approved by the Agent acting on the instructions of all of the Lenders, provided that such approved person accedes to the Security Documents as a
Sponsor and/or Borrower Shareholder (as applicable) in respect of its proportionate direct or indirect ownership interest in the Borrower; 

 PROVIDED THAT 
  

	 	(ee)	in each case, in order to satisfy the requirement to accede to the Security Documents and as a condition precedent to the transfer of any shares to such party, such
Qualifying Entity, Affiliate or other approved person, as the case maybe, shall in each case, have first entered into such documents including where it becomes a Borrower Shareholder, a share charge in favour of the Security Trustee in the same form
as the Share PledgesCharges and in each case in form and substance satisfactory to the Agent and as shall deem necessary provide the Agent with such evidence including
corporate authorities and such legal opinions as the Agent shall require in order for the Agent to be satisfied that such party has acceded to the Security Documents as a Borrower Shareholder and/or Sponsor as the case maybe; and

 (c) provided that at all times during the Facility Period one or more of Mitsui, NYK, Teekay or (following any
transfer permitted and as referred to in (a) above) Teekay LNG or its Wholly-Owned Subsidiary shall directly or indirectly maintain a shareholding in the Borrower of an amount in aggregate which shall not be less than sixty six per cent
(66%) of the full issued and outstanding share capital of the Borrower from time to time; and 

  
 50 

	9.2.18	Replacement of Manager 

without the prior written consent of the Agent (acting on the instructions of the Majority Lenders) and KEIC replace the Manager, provided
that (a) the Agent’s consent shall not be required if the Manager is replaced by NYK LNG with the management of the Vessel further subcontracted to NYK Shipmanagement (UK) Ltd. and (b) the Agent’s consent shall not be
unreasonably withheld or delayed where the Time Charterer has exercised its option pursuant to clause 29.6 of the Time Charter to convert the Time Charter into a bareboat charter of the Vessel; 

 

	9.3	Pre-delivery positive undertakings 

 The Borrower, hereby undertakes and agrees with each of the Lender Finance Parties that from the date of this Agreement until the Delivery Date or, if earlier, the date upon which no moneys are owing
under the Security Documents and no Commitments remain outstanding, that it will: 
  

	9.3.1	Document of title to the Vessel 

 give irrevocable instructions to the Builder that at any time upon which title to the Vessel shall be or become transferable and be capable of transfer to hold the Vessel and the Builder’s
Certificates and any other document of title to the Vessel to the order and at the disposal of the Security Trustee and use its best endeavours to ensure that the Builder complies with such instructions; 

 

	9.3.2	Performance of the Building Contracts 

 duly and punctually observe and perform all the conditions and obligations imposed on it by the Building Contract; 
  

	9.3.3	Performance by Builder 

exercise best endeavours to ensure that the Builder observes and performs all conditions and obligations imposed on it by the Building
Contract and take all steps within its power to ensure that the Builder proceeds with the construction of the Vessel with due diligence and despatch in accordance with the Building Contract; 

 

	9.3.4	Arbitration under the Building Contract 

 in the event that the Builder and/or the Borrower resort to arbitration as provided in Article XXVII of the Building Contract, immediately notify the Agent in writing that such arbitration has been
initiated, advise the Agent in writing of the identity of the appointed arbitrators and upon termination of the arbitration notify the Agent in writing to that effect and supply the Agent with a copy of the arbitration award and a certified English
translation thereof (if the award is not in English); 
  

	9.3.5	Conveyance on default 

where the Vessel is (or is to be) sold in exercise of any power contained in the Security Documents or otherwise conferred on the Security
Trustee, to execute, forthwith upon request by the Agent, such form of conveyance of the Vessel as the Agent may require; 
  

	9.3.6	Enforcement of Borrower’s rights 

 do or permit to be done each and every act or thing which the Agent and/or the Security Trustee may from time to time require to be done in accordance with the terms of the Security Documents for the
purpose of enforcing the Borrower’s rights (which the Borrower have failed to enforce or to enforce in a manner reasonably satisfactory to the Security Trustee) under or pursuant to the Building Contract; 

  
 51 

	9.3.7	Notification of rejection of Vessel 

 notify the Agent and the Security Trustee immediately if the Builder exercises, or purports to exercise or gives notice (written or oral) of its intention to exercise any right to cancel, rescind,
repudiate or otherwise terminate the Building Contract or to render a performance materially different from that which the Building Contract obliges it to render or (with the prior written consent of the Agent given pursuant to clause 9.4.6) the
Borrower cancels, rescinds, repudiates or otherwise terminates the Building Contract or purports to do so or (with the prior written consent of the Agent given pursuant to clause 9.4.6) the Borrower rejects the Vessel or purports to do so or if the
Vessel shall become a Total Loss or partial loss or shall be damaged in a manner affecting its Classification or the Refund Guarantor cancels, rescinds, repudiates or otherwise terminates the Refund Guarantee or purports to do so; 

 

	9.3.8	Vessel name and registration 

 register the Vessel under the laws and flag of the Flag State immediately upon its Delivery and keep the Vessel so registered at all times from the Delivery Date in accordance with clause 9.1.23;

  

	9.3.9	Non-compliance with Time Charter 

 provide the Agent with full details of any matter relating to the construction of the Vessel which could result in the Vessel not being in compliance with the Time Charter within 30 days of such matter
coming to the attention of or being brought to the attention of the Borrower; 
  

	9.3.10	Delays 

 provide the Agent
with full details regarding any delays which arise or may arise with respect to the Scheduled Delivery Date of the Vessel under the Building Contract promptly upon such delays or possible delays coming to the attention of or being brought to the
attention of the Borrower; and 
  

	9.3.11	Mortgage 

 execute, and
procure the registration of, the Mortgage under the laws and flag of the Flag State and the Deed of Covenant immediately upon the Delivery. 
  

	9.4	Pre-delivery negative undertakings 

 The Borrower, hereby further undertakes and agrees with each of the Lender Finance Parties that from the date of this Agreement until the Delivery Date or, if earlier, the date upon which no moneys are
owing under the Security Documents and no Commitments remain outstanding, it will not without the prior written consent of the Agent (and then only subject to such conditions as the Agent may impose) acting on the instructions of the Majority
Lenders and KEIC: 
  

	9.4.1	Sale or other disposal 

sell or agree to sell, transfer, abandon or otherwise dispose of the Vessel or any share or interest therein; 

 

	9.4.2	Creation of Encumbrances 

create or agree to create or permit to exist any Encumbrance over the Vessel (or any share or interest therein) or over the Building
Contract, the Guarantee Bond or the Refund Guarantee other than the Encumbrances created or to be created pursuant to or as contemplated by the Security Documents and Permitted Encumbrances; 

  
 52 

	9.4.3	Variation of Contracts 

agree to any variation of the Building Contract or any substantial variation of the specification of the Vessel (and for the purpose of
this paragraph any extras, additions or alterations which the Borrower may desire to effect in the building of the Vessel shall be deemed to constitute a substantial variation of the specification of the Vessel if the cost thereof (which shall in
every case be agreed in writing between the Borrower and the Builder before the work in respect of such variation is put in hand irrespective of whether the prior consent thereto of the Agent be required hereunder) or if the cost of the modification
causes or will cause the Total Project Cost (estimated by the Borrower as of such date and notified to the Agent) to exceed one hundred and ten per cent. (110%) of the Scheduled Vessel Project Cost, Provided always that the Agent shall not
unreasonably withhold or delay its consent if the Borrower shall evidence to the Agent that the Borrower is in a position to fund any sums from shareholders funds without prejudicing the Borrower’s ability to complete the construction and
delivery of the Vessel in accordance with the Building Contract Provided further that, nothing in this clause 9.4.3 shall prohibit the Borrower from varying the specification of the Vessel to the extent the Borrower has an obligation to make such
variation of the Vessel pursuant to clause 5.1 of the Time Charter or if such variation is required by applicable Law or the Classification Society. If the Borrower has an obligation to make such variation to the Vessel pursuant to clause 5.1 of the
Time Charter, the Borrower shall notify the Agent in writing of such variation and shall provide the Agent, from time to time at the Agent’s reasonable request, information regarding the variation; 

 

	9.4.4	Releases and waivers of Building Contract 

 release the Builder from any of its obligations under the Building Contract or waive any breach of the Builder’s obligations thereunder or consent to any such act or omission of the Builder as would
otherwise constitute such breach; 
  

	9.4.5	Delays 

 without prejudice
to clause 9.4.3, agree to any variation of the Building Contract or the specification of the Vessel which would delay the time for delivery of the Vessel and be likely in the opinion of the Agent (acting reasonably) to put at risk the acceptance of
the Vessel by the Time Charterer under the Time Charter unless the prior written consent to such variation given in writing by the Time Charterer shall have been provided to the Agent; 

 

	9.4.6	Rejection and cancellation 

either exercise or fail to exercise any right which the Borrower may have to reject the Vessel or cancel or rescind or otherwise terminate
the Building Contract Provided always that any such rejection of the Vessel or cancellation, rescission or other termination of the Building Contract by the Borrower after such consent is given shall be without responsibility on the part of the
Agent which shall be under no liability whatsoever to the extent that such rejection, rescission, cancellation or termination is thereafter adjudged to constitute a repudiation or other breach of the Building Contract by the Borrower Provided always
that if the Agent shall not respond (whether in the positive or the negative) within 30 days of any request for such consent being made the Agent shall be deemed to have consented to such request; 

 

	9.4.7	Assignment of Earnings 

assign or agree to assign otherwise than to the Security Trustee the Earnings or any part thereof; 

 

	9.4.8	Variation of and demands under the Refund Guarantee 

 agree to any variation of the Refund Guarantee nor make any demand for payment under the Refund Guarantee; 

  
 53 

	9.4.9	Release and waiver of Refund Guarantee 

 release the Refund Guarantor from any of its obligations under the Refund Guarantee or waive any breach of the Refund Guarantor’s obligations thereunder or consent to any such act or omission of the
Refund Guarantor as would otherwise constitute such breach; and 
  

	9.4.10	Chartering 

 except
pursuant to the Time Charter, let or agree to let the Vessel on demise charter for any period, or by any time or consecutive voyage charter. 
  

	9.5	Insurances 

  

	9.5.1	The Borrower covenants to ensure and procure at its own expense (and for the avoidance of doubt at no cost and expense to the Lender Finance Parties) that the following
provisions of this clause 9.5 are complied with at all times during the Facility Period in respect of the Vessel. The Borrower confirms that throughout the Facility Period, the Vessel shall be in every respect at the risk of the Borrower.

  

	9.5.2	Maintenance of Insurances 

The Vessel shall be kept insured at no cost to the Lender Finance Parties against: 

 

	 	(a)	fire and usual marine risks (including excess risks) and war risks (including terrorism, sabotage, vandalism, malicious mischief, blocking and trapping);

  

	 	(b)	protection and indemnity risks (including pollution risks) and excess war protection and indemnity risks, on “full entry” terms; 

 

	 	(c)	in respect of such other matters of whatsoever nature and howsoever arising in respect of which insurance would be maintained by a prudent owner or operator of vessels
of a similar age, condition and type as the Vessel; and 

  

	 	(d)	loss of hire,for a minimum
cover period of (i) one hundred and eighty (180) days, with a maximum deductible of fourteen (14) days or (ii) following receipt of a written request from the Agent, such longer period as may from time to time be reasonably and
commercially available in the insurance market for vessels of similar age, size and type as the Vessel, and for a rate of hire at least equal to the rate set out in the Time Charter. 

 

	9.5.3	Terms of Insurances 

 Such
Insurances shall be effected: 
  

	 	(a)	in Dollars or such other currency as the Agent and the Borrower may agree; 

 

	 	(b)	in the case of fire and usual marine risks and war risks (on an agreed value basis) in an amount equal to the Insured Loss Value applicable on the first day of the
period for which the insurances are renewed; 

  

	 	(c)	in the case of protection and indemnity risks (including pollution liability risks), in an amount equal to the highest amount in respect of which cover is in accordance
with customary insurance market practice taken out by prudent owners or operators of vessels of a similar type, size, age, condition and flag as the Vessel with protection and indemnity risks associations that are members of the International Group
of Protection and Indemnity Associations (but in the case of pollution risks, for a minimum amount of one billion Dollars ($1,000,000,000) or where cover for such risks is not available in such an amount, such lesser amount as is the best level of
cover available in the market at the applicable time, having regard to the cover being taken out by prudent owners or operators of similar vessels to the Vessel; 

  
 54 

	 	(d)	in the case of loss of hire insurances in such amounts and upon such terms as shall from time to time be approved in writing by the Agent; 

 

	 	(e)	on terms approved under clause 9.5.18, but subject to a minimum requirement of the scope of coverage of that provided by the Institute Time Clauses and Additional
Perils Clause with their War and Strikes sister clauses extended as necessary or as provided by the equivalent full conditions forms of other nationality (so far as can be reasonably obtained in the market at the applicable time); and

  

	 	(f)	through brokers and with insurance companies and/or underwriters or, in the case of war risks and protection and indemnity risks, in war risks and protection and
indemnity risks associations, in each case approved under clause 9.5.18. 

  

	9.5.4	Further protection for Agent 

 In addition to the terms set out in clause 9.5.3, the Insurances effected under such clause shall: 
  

	 	(a)	in the case of the Insurances in respect of marine risks and war risks, be endorsed by way of a loss payable clause to the effect that: 

 

	 	(i)	payment of a claim for a Total Loss will be made to the Security Trustee (and shall, be applied in accordance with the relevant
provisionsclause 6 of the Intercreditor Deed); and 

  

	 	(ii)	payment of a claim for an amount which equals or exceeds the Threshold
Amountten million Dollars ($10,000,000) shall be paid to the Security Trustee and shall be applied in
accordance with the relevant provisions of the Intercreditor Deed); andas follows: 

 

	 	(A)	Subject to (aa) there being no Event of Default (other than an Event of Default under clause 10.2.1 (Failure
to Pay) which has occurred due to the Vessel being off-hire in order for the necessary repair work to be completed) and (bb) clause 9.5.4(a)(v) below, in the event that the Borrower (or the Sponsors on behalf of the Borrower) have instructed a
shipyard to commence the repair works, which shipyard and repair works are acceptable to the Security Trustee acting reasonably and promptly (and, to the extent that the shipyard and repair works have been approved or nominated by the Time
Charterer, such shipyard and repair works shall be deemed to be acceptable to the Security Trustee for these purposes), and paid for the repairs (such payments to be duly evidenced), to the Borrower (or, as the case may be, the Sponsors) upon
resumption of the Vessel into service under the Time Charter, to reimburse the Borrower (or, as the case may be, the Sponsors) for the amounts so paid; or 

 

	 	(B)	Subject to (aa) there being no Event of Default (other than an Event of Default under clause 10.2.1 (Failure
to Pay) which has occurred due to the Vessel being off-hire in order for the necessary repair work to be completed) and (bb) clause 9.5.4(a)(v) below, in the event that the Time Charterer has instructed a shipyard to commence the repair works, which
shipyard and repair works are acceptable to the Security Trustee acting reasonably and promptly (and, to the extent that the shipyard and repair works have been approved or nominated by the Time Charterer, such shipyard and repair works shall be
deemed to be acceptable to the Security Trustee for these purposes), and paid for part or the whole of the repairs and in respect of which the Borrower is required to reimburse the Time Charterer pursuant to paragraph 2.3 of Schedule XI to the Time
Charter, to the Time Charterer to reimburse the Time Charterer for the amounts so paid (and in satisfaction of the Borrower’s obligation to reimburse the Time Charterer pursuant to clause 2.3 of Schedule XI to the Time Charter), with the
balance to be paid to the relevant shipyard conducting such repairs (in or towards payment of any repairs in respect of which payment is outstanding) PROVIDED THAT, where such repairs will require the Vessel to remain off-hire for more than 120
days, the Security Trustee has received prior written confirmation from the Time Charterer that the Time Charterer will not exercise its rights under clause 22.4 of the Time Charter in respect of such off-hire period; and

  
 55 

	 	(C)	if neither the Borrower (nor the Sponsors on behalf of the Borrower) nor the Time Charterer have instructed
a shipyard and paid for the repairs (or, in the case of the Time Charterer, part thereof) as described in clauses 9.5.4(a)(ii)(A) or 9.5.4(a)(ii)(B) above, or the conditions attached to the payment of the amounts to the Borrower, Sponsors or, as the
case may be, Time Charterer (being, in the case of the Borrower, the requirement that that Vessel has resumed service under the Time Charter and, in the case of the Time Charterer, the requirement that where such repairs will require the Vessel to
remain off-hire for more than 120 days, the Security Trustee has received prior written confirmation from the Time Charterer that the Time Charterer will not exercise its rights under clause 22.4 of the Time Charter in respect of such off-hire
period) are not satisfied within forty five (45) days of the completion of the repair works, the Security Trustee shall, acting upon the instruction of the Majority Lenders, have the option to either (a) apply such amounts in repairing the
damage or (b) apply such amounts in accordance with clause 6 of the Intercreditor Deed; and 

  

	 	(iii)	Subject to no Event of Default having occurred which is continuing unremedied and unwaived, payment of a
claim for an amount which is less than ten million Dollars ($10,000,000) shall be made to the Borrower who shall apply the same (a) in or toward making good the loss and fully repairing all damage in respect whereof such payment shall have been
made or (b) to the Time Charterer to reimburse the Time Charterer for amounts paid by the Time Charterer in relation to the repair of the Veessel pursuant to paragraph 2.3 of Schedule XI to the Time Charter; and 

 

	 	(iv)	where there is any surplus after the Insurance proceeds have been applied pursuant to this clause 9.5.4(a)
in respect of the relevant repairs, such surplus Insurance proceeds shall be paid to the Security Trustee for application in accordance with clause 6 of the Intercreditor Deed); and 

 

	 	(v)	the application of clause 9.5.4(a)(ii) above is the subject to the Borrower being in compliance with its
obligation to maintain loss of hire insurance in accordance with clause 9.5.2(d); and 

  

	 	(vi)	(iii) as long as no Event of Default has occurred and is continuing unremedied or unwaived,
payment of any other claim shall be made to the Borrower or, as applicable, such other Security Party, who shall apply the same in or towards making good the loss and fully repairing all damage in respect whereof such payment shall have been made
and after the occurrence of an Event of Default and whilst itif an Event of Default (other than an Event of Default under clause 10.2.1 (Failure to pay) which has occurred due to
the Vessel being off-hire in order for the necessary repair work to be completed), has occurred and is continuing unremedied or unwaived, and following notification by the Security Trustee to the approved brokers, payment of any such claim shall
be made to the Security Trustee, and shall be applied in accordance with the relevant provisionsclause 6 of the Intercreditor Deed; 

 

	 	(b)	in the case of the Insurances in respect of protection and indemnity risks, be endorsed by way of a loss payable clause to the effect that moneys payable thereunder
shall be paid in reimbursement of the assured which has settled the liability to which the relevant claim relates or, if so agreed by the relevant insurers, be paid directly to the person to whom was incurred the liability in respect of which the
relevant money was paid unless and until the Security Trustee, following the occurrence of an Event of Default which is continuing unremedied or unwaived, shall direct that they shall be paid to the Security Trustee whereupon they shall be paid to
the Security Trustee and shall be applied in accordance with the relevant provisionsclause 6 of the Intercreditor Deed; 

  
 56 

	 	(c)	in the case of Insurances in respect of loss of hire be endorsed by way of a loss payable clause to the effect that all moneys payable thereunder shall, be paid to the
Borrower, unless and until the Security Trustee, following the occurrence of an Event of Default which is continuing unremedied or unwaived, shall direct that these shall be paid to the Security Trustee whereupon they shall be paid to the Security
Trustee and shall be applied in accordance with the relevant provisionsclause 6 of the Intercreditor Deed. 

 

	9.5.5	Renewals 

  

	 	(a)	As soon as possible, but in any case not less than fourteen (14) days before the expiry of any of the policies, entries or contracts forming part of the Insurances
or if there is a change in the insurers and/or markets through whom the Insurances are placed, the Borrower shall notify the Agent of the names of the brokers (or other insurers) and any protection and indemnity and/or war risks association through
or with whom such Insurances are proposed to be renewed and (if any material change is proposed) of the proposed terms and amounts of renewal. The Borrower shall also promptly notify the Agent of any material change in the information notified to
the Agent pursuant to this clause 9.5.5 and shall provide the Agent with particulars of such changes. If at any time the terms and amounts on and for which the Insurances are proposed to be renewed or the identity of the broker or war or protection
and indemnity risks associations with whom the Insurances are proposed to be renewed are not approved by the Agent, as contemplated by clause 9.5.18, the Agent shall notify the Borrower promptly in writing of the withdrawal of its approval, and the
Borrower shall procure that the Insurances are renewed or replaced on terms satisfactory to the Agent (acting reasonably); 

  

	 	(b)	Before the expiry of any Insurances the Borrower shall procure that such relevant Insurances are renewed and shall confirm to the Agent that such renewals have been
effected or shall procure that such confirmation is given to the Agent before the expiry of any such Insurances; and 

  

	 	(c)	Promptly after each such renewal, the Borrower shall procure that the Agent is provided with the details of the terms and conditions and amounts on which and for which
such Insurances have been renewed. 

  

	 	(d)	If, after renewal and after review by the Agent of the terms and conditions of renewal, the Agent advises the Borrower that the terms and conditions of such Insurances
as renewed, do not conform with the requirements of this clause 9.5.5 (which advice shall specify in reasonable detail the particular discrepancies) then, after consultation with the Agent, the Borrower shall ensure that any such discrepancies are
corrected promptly. 

  

	9.5.6	Custody of Policy Documents/Loss Payable Clauses 

 The Borrower shall procure that there shall be deposited with the brokers and/or insurers through which the Insurances are arranged from time to time copies of all slips, cover notes, policies
certificates of entry or other instruments of insurance from time to time issued in connection with such of the Insurances referred to in this clause 9.5.6 as are effected through such brokers and/or the war risks and protection and indemnity
association approved in accordance with clause 9.5.18 and shall also procure that, in the case of the Insurances referred to in clause 9.5.2(a), the relevant loss payable clause shall be incorporated on the relevant cover note or policy and, in the
case of the protection and indemnity Insurances referred to in clause 9.5.2(b), the relevant loss payable clause shall be incorporated on the relevant certificate of entry or policy, and the Borrower shall procure that the Agent shall be furnished
with certified copies of the relevant cover note or policy or certificate of entry or policy, duly endorsed. 

  
 57 

	9.5.7	Letters of undertaking 

In relation to all Insurances effected from time to time under and in accordance with this clause 9.5.7, the Borrower shall ensure that
all brokers and/or insurers and any protection and indemnity or war risks associations in which the Vessel is entered, in each case being approved under clause 9.5.18, provide the Agent with letters of undertaking: 

 

	 	(a)	in the case of an approved broker in the form of the L.I.B.C. Recommended Brokers’ Letter of Undertaking of October 1984 or, if such form no longer represents the
then current market practice in the insurance market in which the approved broker operates, in such form as the Agent and the Borrower shall agree, having regard to the then current market practice in the insurance market in which the approved
broker operates, and any professional association of which that approved broker is a member; and 

  

	 	(b)	in the case of a protection and indemnity association, having regard to the current market practice and the practices prescribed by the International Group of
Protection and Indemnity Associations or, if the relevant protection and indemnity association is not a member of the International Group of Protection and Indemnity Associations but has otherwise been approved by the Agent in accordance with clause
9.5.18, the current practice of that association (and which will for all purposes provide for notification to the Agent prior to the cancellation of any such entry); and 

 

	 	(c)	in the case of a war risks association, having regard to the current market practice in the insurance market in which such association operates.

  

	9.5.8	Fleet Cover 

 If any of
the Insurances referred to in clauses 9.5.2(a) and/or 9.5.2(b) form part of a fleet cover, the Borrower will procure that (a) any letter of undertaking referred to in clause 9.5.7 is amended to provide that the relevant brokers shall undertake
to the Lender Finance Parties that they shall neither set-off against any claims in respect of the Vessel any premiums due in respect of other vessels under such fleet cover or any premiums due for other insurances, nor cancel the insurance for
reason of non-payment of premiums for other vessels under such fleet cover or of premiums for such other insurance or (b) that the applicable policy documents are endorsed to the effect that the applicable insurers shall neither set-off against
any claims in respect of the Vessel any premiums due in respect of other vessels under such fleet cover or any premiums due for other insurances, nor cancel the insurance for reason of non-payment of premiums for other vessels under such fleet cover
or of premiums for such other insurance or (c) that the Lender Finance Parties receive other comfort that this will not occur or arranges separate policies for the Vessel. 

 

	9.5.9	No material adverse alteration 

 The Borrower shall comply with the terms and conditions of the Insurances and shall not do and shall ensure that there is no act or omission which would give rise to a right to cancel any Insurances or
render any Insurances, or any policy or policies or certificate or certificates of entry invalid, void, or unenforceable or render any sum paid out under any policy or policies or certificate or certificates of entry or the Insurances evidenced
thereby repayable in whole or in part. The Borrower will not make, and shall procure that there is not made, any material alteration to the terms of any of the Insurances without the prior written consent of the Agent. 

 

	9.5.10	Operation outside terms of Insurances 

 The Borrower will take all steps necessary so that: 
  

	 	(a)	the Vessel is not operated in any way inconsistent with the provisions or warranties of or implied in, or in contravention of the cover provided by, any Insurance taken
out in accordance with this clause 9.5; 

  
 58 

	 	(b)	the Vessel is not engaged in any voyage or to carry any cargo not permitted by any Insurance, in each case without first obtaining the consent (if necessary) of the
insurers to such operation or engagement and complying with such requirements as to extra premium or otherwise as the insurers may prescribe; or 

  

	 	(c)	all requisite certificates of financial responsibility and/or other consents, licences, approvals or Authorisations as may from time to time be required are obtained
and maintained if the Vessel is likely to be operating in or into or off-shore from the United States of America. 

  

	9.5.11	Payment of premiums and calls 

 The Borrower shall procure that (taking account of any applicable grace period) all premiums, calls, contributions or other sums of money from time to time due in respect of any Insurance are paid
punctually and in full. 
  

	9.5.12	Notification of Total Loss 

The Borrower shall procure that the Agent is notified of: 
  

	 	(a)	the levy of any distress on the Vessel or its arrest, detention, seizure, condemnation as prize, Compulsory Acquisition or requisition for title or use; and

  

	 	(b)	(save in the case of Compulsory Acquisition or requisition for title or use or any capture, seizure, arrest, detention or confiscation of the Vessel by any government,
or by persons acting or purporting to act on behalf of any government) any accident, casualty or other event which has caused or resulted in or is likely to cause or result in the Vessel being or becoming a Total Loss. 

 

	9.5.13	Settlement of claims 

  

	 	(a)	The Borrower shall do all things necessary and provide all documents, evidence and information to enable the Lender Finance Parties to collect or recover any moneys
which at any time become due and payable to the Lender Finance Parties or otherwise in respect of the Insurances. 

  

	 	(b)	Subject to the Borrower having provided any necessary security in a timely manner so as to prevent the actual or continued arrest of the Vessel and provided that no
Event of Default shall have occurred and be continuing, the Agent agrees that the Borrower shall have the right to settle, compromise or abandon any claim under the Insurances for Total Loss or in respect of claims in excess of the Threshold Amount
or to give notice of abandonment of the Vessel to the insurers and/or to claim a constructive Total Loss upon the prior written approval of the Agent (such approval not to be unreasonably withheld or delayed, the Borrower acknowledging (without
limitation) that it shall be reasonable for the Agent to withhold its consent if required to do so pursuant to the Relevant Documents or any of them) but that the Agent itself shall not settle, compromise or abandon any such claim without reference
to the Borrower prior to the occurrence of any Event of Default. After the occurrence of any Event of Default while it is continuing unremedied or unwaived, the Security Trustee alone shall have the right to settle, compromise or abandon any claims
under the Insurances and/or give notice of abandonment of the Vessel to the insurers and/or claim a constructive Total Loss. 

  

	9.5.14	P & I guarantees 

 The
Borrower shall arrange for the execution and delivery of all guarantees and indemnities as may from time to time be required by the Vessel’s protection and indemnity or war risks association. 

  
 59 

	9.5.15	Additional Insurance 

Nothing in this clause 9.5.15 shall prohibit the Borrower from placing additional insurance on the Vessel at its own expense and for its
sole benefit provided however that: 
  

	 	(a)	such insurance shall not prejudice the Insurances or recovery thereunder or exceed the amount permitted by warranties or other conditions contained in the Insurances
without the written consent of the insurers of the Insurances; 

  

	 	(b)	where the written consent of the insurers as referred to in clause 9.5.15(a) is required, the Borrower shall procure that there shall be immediately furnished to the
Agent a copy of such consent and, in all cases, with particulars of any additional insurance effected including copies of any cover notes or policies and of the written consent of the insurers of the required insurance in any case where such consent
is necessary; and 

  

	 	(c)	any insurance payments received by the Agent arising solely from additional insurance effected by the Borrower under this clause 9.5.15(a) less amounts due (if any) by
the Agent in respect of Taxes in relation to the sums received shall be paid by the Agent to the Borrower promptly after receipt thereof. 

  

	9.5.16	No Security Interest 

 The
Borrower shall not, and shall procure that no Security Party will, create or permit to exist any security interest over or in respect of the Insurances save for the approved brokers’ or insurers’ right of set off and lien for unpaid
premiums to the extent permitted by clause 9.5.8 and the Encumbrances created by the Assignment. 
  

	9.5.17	Insurance reports and provision of information 

  

	 	(a)	The Borrower shall procure that there shall be provided promptly any information reasonably required for the purpose of the Agent obtaining or preparing any report from
a reputable international independent marine insurance broker or adviser appointed by the Agent as to the adequacy of the Insurances effected or proposed to be effected, and the Borrower shall, promptly upon demand, indemnify the Agent in respect of
reasonable fees incurred by or for the account of the Agent in connection with one such report prepared immediately prior to the Delivery Date and at annual intervals thereafter, but in the case of each annual report only following either any
material change to the terms of any of the Insurances or a change in the identity of the approved brokers, the approved protection and indemnity and/or war risks association or the approved insurance companies and/or underwriters.

  

	 	(b)	The Borrower shall also, on the Agent’s request (not more frequently than annually and, in case of a policy period of more than 12 Months, not more than once in
each policy period), provide to the Agent and the Security Trustee certified copies of all policy documents and certificates of entry relating to the Insurances which are in the possession of the Borrower, its agents or managers or the approved
brokers. 

  

	9.5.18	Approval process 

 The
Agent’s written approval acting on the instructions of the Majority Lenders and KEIC’s written approval must be obtained in relation to the initial placement of Insurances, particularly with respect to requirements as to amounts and terms
of insurance and identity of brokers and the identity and credit standing of the insurers. The Agent’s written approval acting on the instructions of the Majority Lenders and KEIC’s written approval must also be obtained in relation to any
material changes to the amounts and terms of insurance or the identity of the brokers or the identity and credit standing of the insurers on renewal. The Agent will act promptly and will not act unreasonably in relation to giving its approval in
relation to these matters. 

  
 60 

	9.5.19	Mortgagee’s interest insurance/Mortgagee’s additional perils insurance 

Nothing contained in this clause 9.5 shall affect the Security Trustee’s rights to take out mortgagee’s interest insurance,
mortgagee’s additional perils insurance and/or contingent liability insurance in relation to the insurances of the Vessel for its own account save that mortgagee’s interest insurance in respect of the Buyer Credit (and taken for the sole
benefit of the Buyer Credit only) will be affected at the expense of the Borrower. 
  

	9.5.20	Insurance review 

 From
time to time during any period of insurance cover the Agent may review the terms of and identity of brokers, insurance companies and underwriters and war risks or protection and indemnity associations through which the Vessel is insured under this
clause 9.5.20. Such review shall be made in consultation with the Borrower. After consultation, the Borrower shall implement such modifications as the Agent may reasonably request in order to seek to ensure that such insurances at all times cover
all risks which may customarily and generally be covered in transactions similar to that covered by this Agreement and that the terms of such insurances and the identity of brokers, underwriters, insurance companies and associations will continue to
be approved by the Agent, as provided for in clause 9.5.18. 
  

	9.5.21	Insurances effected by the Agent 

 If the Borrower fails to effect or keep in force the Insurances, the Agent may (but shall not be obliged to) effect and/or keep in force such insurances on the Vessel and such entries in protection and
indemnity or war risks associations as the Agent in its discretion considers desirable having regard to the types of insurances that are required pursuant to this clause 9.5, and the Agent may (but shall not be obliged to) pay any unpaid premiums,
calls or contributions. The Borrower will reimburse the Agent from time to time on demand for all such premiums, calls or contributions paid by the Agent, together with interest at the Default Rate from the date of payment by the Agent until the
date of reimbursement 
  

	9.5.22	Environmental 

 The
Borrower shall comply strictly with the requirements of any legislation relating to pollution or protection of the environment which may from time to time be applicable to the Vessel in any jurisdiction in which the Vessel shall trade and in
particular (if a Vessel is to trade in the United States of America and Exclusive Economic Zone (as defined in the Act)) the Borrower shall comply strictly with the requirements of the United States Oil Pollution Act 1990 (“the
Act”). Before any such trade is commenced and during the entire period during which such trade is carried on, the Borrower shall:- 
  

	 	(a)	pay any additional premiums and satisfy such other conditions required to maintain protection and indemnity cover for oil pollution up to the limit available to the
Borrower for the Vessel in the market; and 

  

	 	(b)	make all such quarterly or other voyage declarations as may from time to time be required by the Vessel’s protection and indemnity association in order to maintain
such cover; and 

  

	 	(c)	in addition to the foregoing (if such trade is in the United States of America and Exclusive Economic Zone): 

 

	 	(i)	obtain and retain a certificate of financial responsibility under the Act in form and substance satisfactory to the United States Coast Guard and upon request provide
the Agent with a copy; and 

  

	 	(ii)	procure that the protection and indemnity insurances do not contain a US Trading Exclusion Clause or any other provision analogous thereto and upon request provide the
Agent with evidence that this is so; and 

  

	 	(iii)	comply strictly with any operational or structural regulations issued from time to time by any relevant authorities under the Act so that at all times the Vessel falls
within the provisions which limit strict liability under the Act for oil pollution. 

  
 61 

	9.6	Operation and Maintenance 

  

	9.6.1	General 

 The Borrower
undertakes in favour of the Lender Finance Parties to comply with the following provisions at all times during the Facility Period until such time as the Vessel is sold except as the Agent may otherwise permit in writing. 

 

	9.6.2	Supply and crewing 

Throughout the Facility Period the Borrower shall procure that the Vessel is manned, victualled, navigated, operated, supplied, fuelled,
maintained and repaired, all at no cost to the Agent. 
  

	9.6.3	Condition of the Vessel 

The Borrower shall procure that the Vessel and every part thereof is kept in a good and safe condition and state of repair, ordinary wear
and tear excepted and shall ensure that all repairs to the Vessel or replacements of lost, damaged or worn parts and equipment in respect of the Vessel, are effected in such a manner so as not to diminish the value of the Vessel and in any event:

  

	 	(a)	consistent with first-class ship ownership, operation and management standards in relation to ships of the Vessel’s age and type; 

 

	 	(b)	so as to maintain the Vessel’s present class, namely 1+HULL+MACH+Liquefied gas carrier/LNG, Shiptype 2G (-163°C, 500 kg/m3., 0.25 bar unrestricted navigation +
VeriSTAR-HULL, + AUT-UMS,+SYS-NEQ-1,+MON-SHAFT, INWATERSURVEY, with the American Bureau of Shipping or the equivalent with another Classification Society approved by the Majority Lenders in writing and in each case free from any overdue
recommendations and conditions affecting the Vessel’s class; and 

  

	 	(c)	so as to comply with the material provisions of all laws and regulations applicable to the Vessel, including, without limitation, Environmental Law and Environmental
Approval, and to maintain all certificates, licences and permits applicable to vessels registered in the state of registration for the time being of the Vessel and to vessels trading to any jurisdiction to which the Vessel may trade from time to
time in any such case. 

  

	9.6.4	Master, officers and crew 

The Master, officers and crew of the Vessel shall be the servants of the Borrower for all purposes whatsoever. The Borrower shall ensure
that the wages and allotments and the insurance and pension contributions as appropriate of the Master, officers and crew shall be paid when due and all deductions from their wages in respect of tax liability shall be properly accounted for and the
Master shall have no valid claim for disbursements other than those incurred by him in the ordinary course of trading of the Vessel. 
  

	9.6.5	Modifications 

 The
Borrower shall procure that no modification is made to the Vessel, unless such modification is required to be made by the Borrower pursuant to clause 5.1 of the Time Charter or is otherwise required under applicable Law or by the Classification
Society, which would: 
  

	 	(a)	materially and adversely alter the structure, type or performance characteristics of the Vessel; or 

 

	 	(b)	reduce the value of the Vessel, 

and the Borrower shall notify the Agent of any modifications which are made to the Vessel the cost of which exceeds or will when completed
exceed two million Dollars ($2,000,000). 

  
 62 

	9.6.6	Surveys 

 The Borrower
shall procure that the Vessel is submitted to such periodical or other surveys as may be required by the Flag State or for classification purposes and shall comply with all conditions and recommendations affecting the Vessel’s class of the
relevant Classification Society of the Vessel from time to time in accordance with their terms unless waived and the Borrower shall supply copies of any survey reports to the Agent upon request from the Agent. 

 

	9.6.7	Drydocking 

 The Borrower
shall procure that the Vessel is drydocked as often as may be required to ensure that the Vessel maintains its Classification with its relevant Classification Society and otherwise in accordance with good commercial practice. If the Borrower fails
to comply with the requirements of the relevant Classification Society, the Agent may inspect the Vessel in accordance with clause 9.6.12. If requested by the Agent, the Borrower shall give the Agent reasonable prior written notice of any intended
drydocking of the Vessel. 
  

	9.6.8	Release from arrest 

 The
Borrower shall promptly pay and discharge all debts, damages, liabilities and outgoings whatsoever which have given or which may reasonably be expected to give rise to maritime, statutory or possessory liens on, or claims enforceable against, the
Vessel or the Insurances or any part thereof. If at any time during the Facility Period any writ or equivalent claim or pleading in admiralty is filed against the Vessel or the Insurances or any part thereof, or the Vessel or the Insurances or any
part thereof is arrested or detained or attached or levied upon pursuant to legal process or purported legal process or in the event of the detention of the Vessel in the exercise or the purported exercise of any such lien or claim as aforesaid
(other than by reason of a Compulsory Acquisition), the Borrower shall procure the release of the Vessel and the Insurances from such arrest, detention, attachment or levy or, as the case may be, the discharge of the writ or equivalent claim or
pleading in admiralty as soon as reasonably practicable and in any event within fourteen (14) days (or such longer period as the Agent may agree acting reasonably) of receiving notice thereof by providing bail or procuring the provision of
security or otherwise as circumstances may require. 
  

	9.6.9	Manuals and technical records 

 The Borrower shall procure that: 
  

	 	(a)	all such records, logs, manuals, technical data and other materials and documents which are required to be maintained in respect of the Vessel to comply with any
applicable laws or the requirements of the Flag State and Classification Society are maintained; 

  

	 	(b)	accurate, complete and up-to-date logs and records of all voyages made by the Vessel and of all maintenance, repairs, alterations, modifications and additions to the
Vessel are kept in accordance with good industry practice; and 

  

	 	(c)	following the occurrence of an Event of Default and for as long as it is continuing unremedied or unwaived on reasonable advance notice from the Agent, the Agent or its
representatives is permitted at any time to examine and take copies of such logs and records and other records. 

  

	9.6.10	Vessel’s Software 

  

	 	(a)	The Borrower shall obtain and maintain and procure that there are obtained and maintained all licences and permits (without liability on the part of the Agent for the
payment of any royalties as may be required from time to time in respect of the computer software which is required for the operation of the Vessel, including, but not limited to, navigation software) and shall procure that all such licences and
permits are granted without any limitation or expiry (or are renewed prior to any such expiry). 

  

	 	(b)	The Borrower shall use its best endeavours to extend to the Security Trustee the benefit of all software licences and permits in respect of the Vessel which are
available to the Borrower. 

  
 63 

	9.6.11	Manager 

 Other than the
Manager, and subject to clause 9.2.18 above, the Borrower shall procure that no commercial or technical manager or construction supervisor of the Vessel is appointed without the prior written consent of the Agent (acting on the instructions of the
Majority Lenders) and KEIC, such consent not to be unreasonably withheld or delayed, and the Borrower shall ensure that the Vessel is at all times under such commercial and technical management. 

 

	9.6.12	Inspection 

 The Borrower
shall ensure that the Agent, its surveyors or other persons appointed by it will be permitted to inspect the Vessel (provided that, if no Event of Default has occurred and is continuing unremedied or unwaived, the Agent may not inspect the Vessel
more than once annually), upon reasonable notice and without interfering with the Vessel’s operation. Such inspections shall be without cost or risk to the Borrower unless an inspection made after the occurrence of an Event of Default that is
continuing unremedied or unwaived, in which case the inspections shall be at the cost of the Borrower and the risk of the Agent. 
  

	9.6.13	Notification of certain events 

 The Borrower shall, immediately upon the same coming to its attention and to the best of its then current knowledge, notify the Agent by electronic mail of: 

 

	 	(a)	any casualty or damage in respect of the Vessel which is or is likely to give rise to a loss or cost or repairs of two million Dollars ($2,000,000) or more;

  

	 	(b)	any occurrence as a result of which the Vessel has become or is, by the passing of time or otherwise, likely to become a Total Loss; 

 

	 	(c)	any requirement or recommendation made by any insurer or Classification Society or by any competent authority which is not complied with within any applicable time
period for compliance stipulated by such authority; 

  

	 	(d)	any arrest or detention of the Vessel, any exercise or purported exercise of any lien on the Vessel or its Earnings or any requisition of the Vessel for hire;

  

	 	(e)	any Environmental Claim made against the Agent of which it is or becomes aware or in connection with the Vessel, or any Environmental Incident or Environmental Claim in
an amount in excess of one million Dollars ($1,000,000) or the Dollar Equivalent (in the case of a claim in any other currency) made against the Borrower, any other Security Party or the Time Charterer in connection with the Vessel;

  

	 	(f)	any claim for breach of the ISM Code or the ISPS Code being made against the Borrower, any other Security Party or the Time Charterer in connection with the Vessel;

  

	 	(g)	any other matter, event or incident which will or is reasonably likely to lead to the ISM Code or the ISPS Code not being complied with; 

 

	 	(h)	any claims made in connection with a bodily injury to a third party involving amounts in excess of an amount of one million Dollars ($1,000,000) or the Dollar
Equivalent (in the case of a claim in any other currency); 

  
 64 

	 	(i)	any requisition of the Vessel for hire; 

  

	 	(j)	any security interest (other than a Permitted Encumbrance) arising over the Vessel or the Insurances or Requisition Compensation; and 

 

	 	(k)	any other event in respect of the Vessel or the Insurances or Requisition Compensation which could reasonably be expected to involve the Agent in any loss or liability,

 and the Borrower shall keep the Agent advised in writing on a regular basis and in such reasonable detail as the
Agent shall require in respect of those events or matters and/or of the response to any of those events or matters by the Borrower or the applicable Security Party, the Time Charterer or any other person. 

 

	9.6.14	Restrictions on chartering or parting with possession 

 The Borrower shall not, without the prior written consent of the Agent acting on the instructions of the Majority Lenders (acting reasonably, and without unreasonable delay): 

 

	 	(a)	let or otherwise charter the Vessel to any other party or allow the Vessel to be used by or available to any other party, except pursuant to the Time Charter or except
as required by the Time Charterer under the Time Charter; 

  

	 	(b)	make any amendment to the Time Charter (other than as permitted under clause 9.1.15(b)), or waive any material provision of such Time Charter, or terminate such Time
Charter; 

  

	 	(c)	put the Vessel into the possession of any person for the purpose of work being done upon it in an amount exceeding or likely to exceed two million Dollars ($2,000,000)
or the equivalent in any other currency (in the case of a claim in any other currency) unless either: 

  

	 	(i)	the cost of such work is covered by Insurances; or 

  

	 	(ii)	the Borrower establishes to the reasonable satisfaction of the Agent that it has sufficient funds to pay for the cost of such work. 

Provided always that this clause 9.6.14(c) shall not apply in respect of the regularly scheduled dry docking of the Vessel for which the
Borrower has reserved amounts in accordance with clause 8.2. 
  

	9.6.15	Additional Vessel Covenants 

 The Borrower further covenants with the Agent in respect of the Vessel:- 
  

	 	(a)	at and from the Delivery Date to effect and maintain registration of the Mortgage at the Vessel’s Vessel Registry; and not cause nor permit to be done any act or
omission as a result of which that registration or the registration set out in clause 9.1.23 above might be defeated or imperilled; and 

  

	 	(b)	in the event of any requisition or seizure of the Vessel, to take all lawful steps to recover possession of the Vessel as soon as it is entitled to do so; and

  

	 	(c)	to give to the Agent from time to time during the Facility Period on request such information as the Agent may reasonably require with regard to the Vessel’s
employment, position and state of repair; and 

  
 65 

	 	(d)	not during hostilities (whether or not a state of war shall formally have been declared and including, without limitation, any civil war) to permit the Vessel to be
employed in carrying any goods which may be declared to be contraband of war or which may render that Vessel liable to confiscation, seizure, detention or destruction, nor to permit the Vessel to enter any area which is declared a war zone by any
governmental authority or by the Vessel’s insurers unless the Borrower has effected at its own expense such additional insurances as shall be necessary or customary for first class ship owners. The Borrower shall promptly notify the Agent
thereof and, if required by the Agent, specifically assign those insurances to the Security Trustee by such documents as the Agent, acting reasonably, may require; and 

 

	 	(e)	not without the prior written consent of the Agent to enter into any agreement or arrangement for sharing the Earnings; and 

 

	 	(f)	to take all reasonable precautions to prevent any infringements of any anti drug legislation in any jurisdiction in which the Vessel shall trade and in particular (if
the Vessel is to trade in the United States of America) to take all reasonable precautions to prevent any infringements of the Anti-Drug Abuse Act of 1986 of the United States of America and for this purpose, if required, to enter into a
“Carrier Initiative Agreement” with the United States’ Customs Service and to procure that the same or a similar agreement is maintained in full force and effect and that the Borrower’s obligations thereunder are performed in
respect of the Vessel. 

  

	10	Events of Default 

  

	10.1	The Agent’s rights 

If any of the events set out in clause 10.2 occurs, the Agent may at its discretion (and, on the instructions of the Majority Lenders,
will): 
  

	10.1.1	by notice to the Borrower declare the Lenders to be under no further obligation to the Borrower under or pursuant to this Agreement and may (and, on the instructions of
the Majority Lenders, will) declare all or any part of the Lender Indebtedness (including such unpaid interest and Commitment Fees as shall have accrued and any Break Costs incurred by the Lender Finance Parties) to be immediately payable, whereupon
the Lender Indebtedness (or the part of the Lender Indebtedness referred to in the Agent’s notice) shall immediately become due and payable without any further demand or notice of any kind; and/or 

 

	10.1.2	declare that any undrawn portion of the Loan shall be cancelled, whereupon the same shall be cancelled and the corresponding Commitment of each Lender shall be reduced
to zero; and/or 

  

	10.1.3	exercise any rights and remedies in existence or arising under the Security Documents. 

 

	10.2	Events of Default 

 The
events referred to in clause 10.1 are:- 
  

	10.2.1	Failure to Pay: any Security Party fails to pay any amount payable by it under this Agreement or any of the Security Documents at the time, in the currency and
otherwise in the manner specified herein or therein (and so that, for this purpose, sums payable on demandunscheduled amounts shall be treated as having been paid at
the stipulated time if paid within five (5) days of demand) unless in respect of scheduled payments the Borrower demonstrates to the satisfaction of the Agent that such failure has occurred by reason solely of banking error and such sum remains
unpaid for no longer than five (5) days after the date on which it receives notice from the Agent of such failure; or 

  

	10.2.2	if any of the Borrower, the Sponsors or the Borrower Shareholders fails to pay when due any amount payable by it under any of the Project Documents to which it is a
party at any time, in the currency and otherwise in the manner specified therein subject to expiry of any applicable grace periods specified therein and if such failure in the reasonable opinion of the Agent (acting on the instructions of the
Majority Lenders) has or may be likely to have a Material Adverse Effect; or 

  
 66 

	10.2.3	Insurances: any of the Insurances required to be placed and maintained in respect of the Vessel in accordance with clause 9.5 are not so placed and/or maintained
or if at any time any of the Insurances either: 

  

	 	(a)	lapse before the time of scheduled renewal without being renewed in accordance with clause 9.5; or 

 

	 	(b)	are not renewed at the time of scheduled renewal in accordance with the requirements of clause 9.5; or 

 

	 	(c)	are cancelled or rendered invalid, void or unenforceable, 

 any sums recovered under any of the Insurances for the Vessel are or become repayable in whole or in part and an equivalent amount is not paid by the Borrower within 2 Business Days; or 

 

	10.2.4	Misrepresentation: any representation or statement made by any Security Party in favour of a Lender Finance Party in this Agreement or any Security Document to
which it is a party or, in each case, in any notice or other document, certificate or statement delivered by it pursuant thereto or in connection therewith is or proves to have been incorrect or misleading in any material respect when made and in
each case where the incorrectness is in the opinion of the Agent (acting on the instructions of the Majority Lenders) remediable and the relevant Security Party shall have failed to remedy it within fifteen (15) days after receipt by the
relevant Security Party of a written notice from the Agent of such failure (or such longer period as the Agent (acting on the instructions of the Majority Lenders) may specify or agree); or 

 

	10.2.5	Specific Covenants: the Borrower fails duly to perform or comply with any of the obligations expressed to be assumed by or procured by it under clauses 9.1.4,
9.1.15,9.1.15(a), 9.1.15(b)(i), 9.1.15(b)(ii) 9.1.18, 9.1.19,9.1.19, 9.2.17, 9.4.7,
9.4.8, 9.4.9 or 9.4.10 at any time; or 

  

	10.2.6	Other Obligations: (a) a Security Party fails duly to perform or comply with any other term or condition of any other Security Document to which it is a
party (other than those referred to in clauses 10.2.1, 10.2.2, 10.2.4, 10.2.5, 10.2.23, 10.2.24 or 10.2.25) and such failure is not remedied within fifteen (15) days after the Agent has given written notice thereof to the relevant Security
Party (or such longer period as the Agent (acting on the instructions of the Majority Lenders) may specify or agree) or (b) any Security Party fails duly to perform or comply with any other term or condition of any Project Document to which it
is a party subject to expiry of any applicable grace period therein and if the failure to perform in the reasonable opinion of the Agent (acting on the instructions of the Majority Lenders) has or may be likely to have a Material Adverse Effect; or

  

	10.2.7	Cross-Default: any Financial Indebtedness of the Borrower in an amount greater than two hundred and fifty thousand Dollars ($250,000) is not paid when due or
becomes (whether by declaration or automatically in accordance with the relevant agreement or instrument constituting the same and following expiry of any applicable grace period for payment thereof) due and payable prior to the date when it would
otherwise have become due (unless as a result of the exercise by the Borrower of a voluntary right of prepayment), or any creditor of the Borrower becomes entitled to declare any such Financial Indebtedness due and payable or any facility or
commitment available to the Borrower relating to such Financial Indebtedness is withdrawn, suspended or cancelled by reason of any default (however described) of the Borrower concerned; or 

 

	10.2.8	Litigation: any litigation, arbitration or administrative action or proceeding is commenced against any Security Party or, prior to Delivery, the Builder
or the Refund Guarantor or any of theirits property, undertakings or assets before any court, arbitrator or administrative agency or authority which, if
adversely determined, would have in the reasonable opinion of the Agent a Material Adverse Effect unless: 

  

	 	(a)	the relevant Security Party demonstrates in writing to the Agent (who shall act reasonably in considering such matters) to the Agent’s satisfaction, that such
litigation, arbitration or administrative action or proceeding is or may reasonably be considered to be vexatious or frivolous; or 

  

	 	(b)	it is dismissed or irrevocably stayed within thirty (30) days of commencement; 

  
 67 

	10.2.9	Legal process: 

  

	 	(a)	any final judgment or order greater than two hundred and fifty thousand Dollars ($250,000) made against the Borrower is not stayed or complied with within twenty
(20) Business Days or a creditor attaches or takes possession of, or a distress, execution, sequestration or other process is levied or enforced upon or sued out against, all or a substantial part of (in the reasonable opinion of the Agent) the
undertakings, assets, rights or revenues of the Borrower and is not discharged within twenty (20) Business Days; or 

  

	 	(b)	any final judgment or order made against any Security Party (other than the Borrower and (following the Delivery Date) the Supervisor) is not stayed or complied with
within twenty (20) Business Days or a creditor attaches or takes possession of, or a distress, execution, sequestration or other process is levied or enforced upon or sued out against, all or substantially all of (in the reasonable opinion of
the Agent) the undertakings, assets, rights or revenues of any Security Party (other than the Borrower and (following the Delivery Date) the Supervisor) and is not discharged within twenty (20) Business Days and, in each such case above, the
event described above has or might reasonably be likely to have a Material Adverse Effect; or 

  

	10.2.10	Insolvency: any Security Party (including the Supervisor prior to the Delivery Date only) is unable or admits inability to pay its debts as they fall due;
suspends making payments on any of its debts or announces an intention to do so; becomes insolvent; has assets the value of which is less than the value of its liabilities; or suffers the declaration of a moratorium in respect of any of its
indebtedness; or 

  

	10.2.11	Reduction or loss of capital: a meeting is convened by any Security Party (including the Supervisor prior to the Delivery Date only) for the purpose of passing
any resolution to purchase, reduce or redeem any of its share capital (other than a stock buy-back of any Sponsor); or 

  

	10.2.12	Winding up: any corporate action, legal proceedings or other procedure or step is taken for the purpose of winding up any Security Party (including the
Supervisor prior to the Delivery Date only) or an order is made or resolution passed for the winding up of any Security Party (including the Supervisor prior to the Delivery Date only) or a notice is issued convening a meeting for the purpose of
passing any such resolution, provided however that, in the case only of an order for winding-up, the occurrence of such event shall not constitute an Event of Default if such winding-up has commenced as part of a process of a fully-solvent
reorganisation, previously approved by the Agent acting on the instructions of the Majority Lenders and which shall not have a Material Adverse Effect, provided further that the Agent shall not have the right to approve a fully-solvent
reorganisation of any of the Sponsors, the Borrower Shareholders, the Manager; or 

  

	10.2.13	Administration: any petition is presented, notice given or other step is taken for the purpose of the appointment of an administrator of any Security Party
(including the Supervisor prior to the Delivery Date only) or an administration order is made in relation to any Security Party (including the Supervisor prior to the Delivery Date only); or 

 

	10.2.14	Appointment of receivers and managers: any administrative or other receiver is appointed of any Security Party (including the Supervisor prior to the Delivery
Date only) or any part of its assets and/or undertaking or any other steps are taken to enforce any Encumbrance over all or any part of the assets of any Security Party (including the Supervisor prior to the Delivery Date only); or

  
 68 

	10.2.15	Compositions: any corporate action, legal proceedings or other procedures or steps are taken, or negotiations commenced, by any Security Party (including the
Supervisor prior to the Delivery Date only) or by any of its creditors with a view to the general readjustment or rescheduling of all or a material part of its indebtedness or to proposing any kind of composition, compromise or arrangement involving
such company and any of its creditors; or 

  

	10.2.16	Analogous proceedings: there occurs, in relation to any Security Party (including the Supervisor prior to the Delivery Date only) in any country or territory in
which any of them carries on business or to the jurisdiction of whose courts any part of their assets is subject, any event which, in the reasonable opinion of the Agent, appears in that country or territory to correspond with, or have an effect
equivalent or similar to, any of those mentioned in clauses 10.2.9 to 10.2.15 (inclusive) (other than clause 10.2.10) or any Security Party (including the Supervisor prior to the Delivery Date only) otherwise becomes subject, in any such country or
territory, to the operation of any law relating to insolvency, bankruptcy or liquidation; or 

  

	10.2.17	Environmental Incidents: there is an Environmental Incident which gives rise, or may be likely to give rise, to Environmental Claims which would reasonably be
expected to have a Material Adverse Effect; or 

  

	10.2.18	Repudiation: any Security Party repudiates any Security Document or Project Document to which it is a party or does or causes to be done any act or thing
evidencing an intention to repudiate any such Security Document or the Project Document, or if the validity or enforceability of any of the Security Documents and the Project Documents shall at any time and for any reason be contested by any
Security Party which is a party thereto, or if any such Security Party shall deny that it has any, or any further, liability thereunder; or 

  

	10.2.19	Cessation of business: any Security Party (including the Supervisor prior to the Delivery Date only) suspends or ceases (or, in the case of the Borrower, any of
the Borrower Shareholders and/or any of the Sponsors threatens to suspend or cease) to carry on its business (or, in the case of the Sponsors a substantial part of its business where the suspension or cessation of such substantial part of its
business has or might have a Material Adverse Effect) except (in the case of the Security Parties (which shall not for this purpose include the Borrower for the purposes of and followed by a reconstruction, amalgamation, reorganisation, merger or
consolidation which shall be undertaken and concluded in such manner as in the reasonable opinion of the Agent will enable such Security Party to perform its obligations pursuant to the Security Documents or Project Documents to which it is a party;
or 

  

	10.2.20	Seizure: all or a material part of the undertaking, assets, rights or revenues of, or shares or other ownership interests in, any Security Party (including the
Supervisor prior to the Delivery Date only) are seized, nationalised, expropriated or compulsorily acquired by or under the authority of any government; or 

 

	10.2.21	Encumbrances enforceable: any Encumbrance (other than Permitted Encumbrance) in respect of any of the property which is the subject of any of the Security
Documents becomes enforceable; or 

  

	10.2.22	Challenge to Registration: if the registration of the Vessel or the Mortgage becomes void or voidable or subject to cancellation or termination; or

  

	10.2.23	Swap Agreements: (a) an Event of Default (in each case as defined in any of the Swap Agreements) on the part of the Borrower has occurred and is continuing
unremedied or unwaived under any of the Swap Agreements or (b) an Early Termination Date (as defined in any of the Swap Agreements) has occurred or been or become capable of being effectively designated under any of the Swap Agreements or
(c) a person entitled to do so gives notice of an Early Termination Date under any of the Swap Agreements or (d) any of the Swap Agreements is terminated, cancelled, suspended, rescinded or revoked or otherwise ceases to remain in full
force and effect for any reason; or 

  
 69 

	10.2.24	Material Events: save (in respect of the security interests created by any of the Security Documents) where the Borrower has taken such action as the Agent
requires pursuant to clause 9.1.12 (Further Assurance) to adequately protect the security interests created by the Security Documents, any other event occurs or circumstance arises which materially and adversely affects the security interests
created by any of the Security Documents or the Refund Guarantee unless the relevant Security Document(s) and/or the Refund Guarantee is replaced or amended to the satisfaction of the Agent forthwith in the case of this Agreement, the Mortgage, the
Refund Guarantee and the Deed of Covenants or within 21 days in the case of the other Security Documents; or 

  

	10.2.25	KEIC Buyer Credit Policy: The obligation of KEIC under the KEIC Buyer Credit Policy shall terminate, become unenforceable or otherwise cease to be in full force
and effect as a result of the acts or omissions of the Borrower. 

  

	10.3	Replacement of Manager or Supervisor: 

 notwithstanding any other provision of the Security Documents, no action or omission by or other matter relating to the Manager or the Supervisor shall result in a misrepresentation, breach of warranty,
breach of undertaking, Potential Event of Default or Event of Default hereunder if: 
  

	 	(a)	such misrepresentation, breach of warranty, breach of undertaking, Potential Event of Default or Event of Default is cured or waived; or 

 

	 	(b)	subject to clause 9.2.18 the Manager or Supervisor is replaced by another person reasonably acceptable to the Agent, 

in either case within 30 days of the date upon which such action, omission or matter would otherwise have been a misrepresentation,
breach, Potential Event of Default or Event of Default and if the Manager or Supervisor is replaced as set out above they shall be replaced on similar terms to the Management Agreement or Supervision Agreement as appropriate subject always to any
misrepresentation, breach, Potential Event of Default or Event of Default being remedied within a reasonable period by such replacement. 
  

	11	Set-Off and Lien  

  

	11.1	Set-off 

  

	11.1.1	The Borrower irrevocably authorises each of the Lender Finance Parties at any time after all or any part of the Lender Indebtedness shall have become due and payable to
set off any liability of the Borrower to any of the Lender Finance Parties (whether present or future, actual or contingent, and irrespective of the branch or office, currency or place of payment) against any credit balance from time to time
standing on any account of the Borrower (whether current or otherwise and whether or not subject to notice) with any branch of any of the Lender Finance Parties in or towards satisfaction of the Lender Indebtedness and, in the name of that Lender
Finance Party or the Borrower, to do all acts (including, without limitation, converting or exchanging any currency) and execute all documents which may be required to effect such application. The relevant Lender Finance Party will notify the
Borrower forthwith upon the exercise or purported exercise of any rights under this clause 11.1. 

  

	11.1.2	For such purposes, each Lender Finance Party is authorised to purchase with the moneys standing to the credit of such account such other currencies as may be necessary
to effect such application. No Lender Finance Party shall be obliged to exercise any right given to it by this clause 11.1. The Lender Finance Party shall notify the Borrower forthwith upon the exercise or purported exercise of any right of set-off
giving full details in relation thereto. 

  

	11.1.3	Without prejudice to their rights hereunder and/or under any of the Swap Agreements, the Swap Providers may at the same time as, or at any time after, any Event of
Default under this Agreement or the Borrower’s default under any of the Swap Agreements set-off any amount due now or in the future from the Borrower to the Swap Providers under this Agreement against any amount due from the Swap Providers to
the Borrower under any of the Swap Agreements and apply the first amount in discharging the second amount. The effect of any set-off under this clause 11.1.3 shall be effective to extinguish or, as the case may require, reduce the liabilities of the
Swap Providers under any of the Swap Agreements. 

  
 70 

	11.2	Lien 

 If an Event of
Default has occurred and is continuing, unremedied or unwaived, each Lender Finance Party shall have a lien on and be entitled to retain and realise as additional security for the repayment of the Lender Indebtedness any cheques, drafts, bills,
notes or negotiable or non-negotiable instruments and any stocks, shares or marketable or other securities and property of any kind of the Borrower (or of that Lender Finance Party as agent or nominee of the Borrower) from time to time held by that
Lender Finance Party, whether for safe custody or otherwise. 
  

	11.3	Restrictions on withdrawal 

Despite any term to the contrary in relation to any deposit or credit balance at any time on any account of the Borrower with any of the
Lender Finance Parties, no such deposit or balance shall be repayable or capable of being assigned, mortgaged, charged or otherwise disposed of or dealt with by the Borrower in question after an Event of Default has occurred and while such Event of
Default is continuing unremedied or unwaived, but any Lender Finance Party may from time to time permit the withdrawal of all or any part of any such deposit or balance without affecting the continued application of this clause. Provided always that
this clause 11.3 shall not apply to the Distribution Account or any credit balance therein. 
  

	12	Assignment and Transfer  

  

	12.1	Right to assign 

  

	12.1.1	Subject to clause 12.9, each of the Lenders may (a) assign or transfer all or any of its rights and/or obligations under or pursuant to the Security Documents or
(b) assign or transfer all or any part of its Commitment any such part being at least US $5,000,000 and an integral multiple of US $1,000,000, (i) to any other branch or Affiliate of that Lender (provided that such Affiliate shall have the
same or a better credit rating than the Lender making the assignment or transfer) to another Lender or (ii) above with the prior written consent of the Agent (which shall not be unreasonably withheld or delayed) and the Borrower (which shall
not be unreasonably withheld or delayed and shall not be required if an Event of Default has occurred and is continuing unremedied or unwaived) to any other bank or financial institution provided that in relation to any transfer or any assignment
under this clause 12.1: 

  

	 	(i)	any transferee under this clause 12.1(a) shall assume all of the relevant Lender’s obligations; 

 

	 	(ii)	the Borrower shall not be liable to pay any costs, charges or expenses of or in connection with the implementation of completion of the assignment or transfer;

  

	 	(iii)	the Borrower shall not, as at the time of any such assignment or transfer, be liable to pay any additional or increased amounts or taxes or suffer a reduction in any
amounts receivable by it under this Agreement for which it would not have been liable or would not have suffered but for such assignment or transfer having then taken place; and 

 

	 	(iv)	the relevant Lender shall give the Borrower five (5) Business Days prior written notice of any intended transfer of obligations. 

 

	12.1.2	Each of the Lenders may, without being restricted or otherwise being bound by clause 12.1.1, assign or transfer all or any part of its rights under or pursuant to this
Agreement and/or any of the other Security Documents to KEIC following the occurrence of an Event of Default which is continuing unremedied or unwaived or otherwise if required to do so by KEIC pursuant to the terms of the KEIC Buyer Credit Policy
provided that KEIC pays first the insurance proceeds in accordance with the KEIC Buyer Credit Policy. 

  
 71 

	12.2	Borrower’s co-operation 

 The Borrower will, at no cost to the Borrower, co-operate fully and will procure that the other Security Parties co-operate fully with the Lender Finance Parties in connection with any assignment or
transfer pursuant to clause 12.1; will execute and procure the execution of such documents as the Lender Finance Parties may reasonably require in connection therewith; and irrevocably authorise each of the Lender Finance Parties to disclose to any
proposed assignee or transferee (whether before or after any assignment or transfer and whether or not any assignment or transfer shall take place) all information relating to the Security Parties, the Time Charterer, the Loan or the Relevant
Documents which each such Lender Finance Party may in its discretion consider necessary to implement such assignment or transfer (subject to any duties of confidentiality applicable to the Borrower and/or Lender Finance Parties). 

 

	12.3	Rights of assignee 

 Any
assignee or transferee of a Lender shall (unless limited by the express terms of the assignment or transfer) take the full benefit of every provision of the Security Documents benefiting that Lender. Such transfer shall not directly result in an
increased cost to, or liability of, the Borrower at the time of transfer. 
  

	12.4	Transfer Certificates 

 If any Lender wishes to transfer all or any of its Commitment as contemplated in clause 12.1 then such transfer may be effected by the delivery to the Agent of a duly completed and duly executed Transfer
Certificate in which event, on the later of the Transfer Date specified in such Transfer Certificate and the fifth
(5th) Business Day after the date of delivery of such
Transfer Certificate to the Agent: 
  

	12.4.1	to the extent that in such Transfer Certificate the Lender which is a party thereto seeks to transfer its Commitment in whole, the Borrower and such Lender shall be
released from further obligations towards each other under this Agreement and their respective rights against each other shall be cancelled other than existing claims against such Lender for breach of this Agreement (such rights, benefits and
obligations being referred to in this clause 12.4 as “discharged rights and obligations”); 

  

	12.4.2	the Borrower and the Transferee which is a party thereto shall assume obligations towards each other and/or acquire rights against each other which differ from such
discharged rights and obligations only insofar as the Borrower and such Transferee have assumed and/or acquired the same in place of the Borrower and such Lender; 

 

	12.4.3	the Lender Finance Parties and the Transferee shall acquire the same rights and benefits and assume the same obligations between themselves as they would have acquired
and assumed had such Transferee been an original party to this Agreement as a Lender with the rights, benefits and/or obligations acquired or assumed by it as a result of such transfer; and 

 

	12.4.4	as between the Agent and the Transferee, the Transferee shall pay to the Agent a transfer fee of three thousand Dollars ($3,000). 

 

	12.5	Power of Attorney 

 In
order to give effect to each Transfer Certificate the Lender Finance Parties and the Borrower hereby irrevocably and unconditionally appoint the Agent as its true and lawful attorney with full power to execute on their respective behalves each
Transfer Certificate delivered to the Agent pursuant to clause 12.4 without the Agent being under any obligation before doing so to take any further instructions from or give any prior notice to, any of the Lender Finance Parties or, subject to the
Borrower’s rights under clause 12.1, the Borrower. The Agent shall so execute each such Transfer Certificate on behalf of the other Lender Finance Parties and the Borrower immediately on receipt of the same by the Agent pursuant to clause 12.4.

  
 72 

	12.6	Notification 

 The Agent
shall promptly notify the other Lender Finance Parties, the Transferee and the Borrower on the execution by it of any Transfer Certificate together with details of the amount transferred, the Transfer Date and the parties to such transfer.

  

	12.7	No Assignment or transfer by the Borrower 

 The Borrower may not assign any of its rights or transfer any of its rights or obligations under the Security Documents without the prior written consent of the Lenders and KEIC. 

 

	12.8	KEIC Buyer Credit Policy 

Not withstanding any provisions to the contrary in this Agreement, in the event KEIC pays the insurance proceeds in full or in part in
accordance with the KEIC Buyer Credit Policy, (i) the obligations of the Borrower under this Agreement shall not be reduced or affected in any manner, (ii) KEIC shall be entitled to exercise the rights of the Lenders in accordance with
clause 9.2 of the Intercreditor Deed, (iii) the provisions of clause 9.1 of the Intercreditor Deed shall apply and (iv) with respect to the obligations of the Borrower owed to the Agent, the Security Trustee and/or the Lenders under the
Security Documents (or any of them) such obligations shall additionally be owed to KEIC to the extent of its interest by way of subrogation of the rights of the Lenders. 

 

	12.9	KEIC Consent 

 A Lender
may not assign or transfer its portion of the Buyer Credit or any part thereof without the consent of KEIC (such consent not to be unreasonably withheld or delayed). 
  

	13	Payments, Reserve Requirements and Illegality 

  

	13.1	Payments 

 All amounts
payable by the Borrower to the Lender Finance Parties under or pursuant to any of the Security Documents shall be paid to such accounts at such banks as the Agent may from time to time direct to the Borrower and shall be paid in Dollars in same day
funds (or such funds as are required by the authorities in the United States of America for settlement of international payments for immediate value). Payments shall be deemed to have been received by the Agent on the date on which the Agent
receives authenticated advice of receipt, unless that advice is received by the Agent on a day other than a Business Day or at a time of day (whether on a Business Day or not) when the Agent in its reasonable discretion considers that it is
impossible or impracticable for the Agent to utilise the amount received for value that same day, in which event the payment in question shall be deemed to have been received by the Agent on the Business Day next following the date of receipt of
advice by the Agent. 
  

	13.2	No deductions or withholdings 

 All payments (whether of principal or interest or otherwise) to be made by the Borrower to the Lender Finance Parties pursuant to the Security Documents shall, subject only to clause 13.3, be made free
and clear of and without deduction for or on account of any Taxes or other deductions, withholdings, restrictions, conditions or counterclaims of any nature, and the Borrower will not claim any equity in respect of any payment due from them to the
Lender Finance Parties under or in relation to any of the Security Documents. 
  

	13.3	Grossing-up 

  

	13.3.1	If at any time any law requires (or is interpreted by any relevant fiscal authority to require) the Borrower to make any deduction or withholding from any payment, or
to change the rate or manner in which any required deduction or withholding is made, the Borrower will promptly notify the Agent and, simultaneously with making that payment, will pay to the Agent whatever additional amount (after taking into
account any additional Taxes on, or deductions or withholdings from, or restrictions or conditions on, that additional amount) is necessary to ensure that, after making the deduction or withholding, the Agent and the Lenders receive a net sum equal
to the sum which they would have received had no deduction or withholding been made. 

  
 73 

	13.3.2	If following the making of any such increased payment by the Borrower pursuant to clause 13.3.1, the Agent or any Lender determines that: 

 

	 	(a)	a credit against, relief or remission for, or repayment of any Tax (a “Tax Credit”) is attributable to any deduction or withholding or increased
payment made by the Borrower; and 

  

	 	(b)	it has obtained, utilised and retained that Tax Credit, 

 the Agent or Lender (as appropriate) shall pay an amount to the Borrower which the Agent or the Lender (as appropriate) determines will leave it (after that payment) in the same after-Tax position as it
would have been had the deduction or withholding or additional payment not been required to be made. 
  

	13.4	Evidence of deductions 

If at any time the Borrower is required by law to make any deduction or withholding from any payment to be made by it to the Lender
Finance Parties pursuant to any of the Security Documents, the Borrower will pay the amount required to be deducted or withheld to the relevant authority within the time allowed under the applicable law and will, no later than thirty (30) days
after making that payment, deliver to the Agent an original receipt issued by the relevant authority, or other evidence reasonably acceptable to the Agent, evidencing the payment to that authority of all amounts required to be deducted or withheld.
If the Borrower makes any deduction or withholding from any payment to the Lender Finance Parties under or pursuant to any of the Security Documents, and a Lender subsequently receives a refund or allowance from any tax authority which that Lender
at its sole discretion (acting reasonably and in good faith) identifies as being referable to that deduction or withholding, that Lender shall within five (5) Business Days of receipt of the same, pay to the Borrower an amount equal to the
amount of the refund or allowance received, if and to the extent that it may do so without prejudicing its right to retain that refund or allowance and without putting itself in any worse financial position than that in which it would have been had
the deduction or withholding not been required to have been made. Nothing in this clause 13.4 shall be interpreted as imposing any obligation on any Lender to apply for any refund or allowance nor as restricting in any way the manner in which any
Lender organises its tax affairs, nor as imposing on any Lender any obligation to disclose to the Borrower any information regarding its tax affairs or tax computations. All costs and expenses incurred by any Lender in obtaining or seeking to obtain
a refund or allowance from any tax authority pursuant to this clause 13.4 shall be for the Borrower’s account. 
  

	13.5	Adjustment of due dates 

If any payment to be made to the Lender Finance Parties under any of the Security Documents, other than a payment of interest on the Loan
(to which clause 6.7 applies), shall be due on a day which is not a Business Day, that payment shall be made on the next succeeding Business Day (unless the next succeeding Business Day falls in the next calendar Month in which event the payment
shall be made on the next preceding Business Day). Any such variation of time shall be taken into account in computing any interest in respect of that payment. 
  

	13.6	Change in law 

 If, by
reason of the introduction of any law, or any change in any law, or the interpretation by the relevant fiscal authority or administration of any law, or in compliance with any request or requirement from any central bank or any fiscal, monetary or
other authority:- 

  
 74 

	13.6.1	any Lender Finance Party (or the Holding Company of any Lender Finance Party) shall be subject to any Tax with respect to payments of all or any part of the Lender
Indebtedness; or 

  

	13.6.2	the basis of Taxation of payments to any Lender Finance Party in respect of all or any part of the Lender Indebtedness shall be changed (other than as a result of any
change in the applicable tax rate in the jurisdiction in which its lending office is based); or 

  

	13.6.3	any reserve requirements shall be imposed, modified or deemed applicable against assets held by or deposits in or for the account of or loans by any branch of any
Lender Finance Party or its direct or indirect Holding Company; or 

  

	13.6.4	any ratio (whether cash, capital adequacy, liquidity or otherwise) which any Lender Finance Party or its direct or indirect Holding Company is required or requested to
maintain shall be affected; or 

  

	13.6.5	there is imposed on any Lender Finance Party (or on the direct or indirect Holding Company of any Lender Finance Party) any other condition in relation to the Lender
Indebtedness or the Security Documents (other than as a result of any change in the applicable tax rate in the jurisdiction in which its lending office is based); 

 and the result of any of the above shall be to increase the cost to any Lender (or to the direct or indirect Holding Company of any Lender) of that Lender making or maintaining its Commitment or its
Drawing, or to cause any Lender Finance Party to suffer (in its reasonable opinion) a material reduction in the rate of return on its overall capital below the level which it reasonably anticipated at the Execution Date and which it would have been
able to achieve but for its entering into this Agreement and/or performing its obligations under this Agreement, the Lender Finance Party affected shall notify the Agent and, on demand to the Borrower by the Agent, the Borrower shall from time to
time pay to the Agent for the account of the Lender Finance Party affected the amount which shall compensate that Lender Finance Party or the Agent (or the relevant Holding Company) for such additional cost or reduced return. A certificate signed by
an authorised signatory of the Agent or of the Lender Finance Party affected setting out the amount of that payment and the basis of its calculation shall be submitted to the Borrower and shall be conclusive evidence of such amount save for manifest
error or on any question of law. 
 Notwithstanding the foregoing, this clause 13.6 does not apply to the extent any increased
cost is: 
  

	 	(a)	attributable to a tax deduction required by law to be made by the Borrower; 

 

	 	(b)	fully compensated for by clause 15.7 (or would have been compensated for under clause 15.7 but was not so compensated solely because any of the exclusions in clause
15.7 applied) or fully compensated for under any other provision of this Agreement; or 

  

	 	(c)	attributable to the wilful breach by the relevant Lender Finance Party (or the Holding Company of any Lender Finance Party) or any of its or their Affiliates of any
law. 

  

	13.7	Illegality and impracticality 

 Notwithstanding anything contained in the Security Documents, the obligations of a Lender to advance or maintain its Commitment shall terminate in the event that a change in any law or in the
interpretation of any law by any authority charged with its administration shall make it unlawful for that Lender to advance or maintain its Commitment. In such event the Lender affected shall notify the Agent and the Agent shall, by written notice
to the Borrower, declare that Lender’s obligations to be immediately terminated. If all or any part of the Loan shall have been advanced by the Lenders to the Borrower, the portion of the Lender Indebtedness (including all accrued interest and
Commitment Fees) advanced by the Lender so affected shall be prepaid on the next Interest Payment Date, or sooner if illegality is determined (but no sooner than the last day of any applicable grace period permitted by law). Clause 5.4 shall apply
to that prepayment if it is made on a day other than the last day of an Interest Period. 

  
 75 

	13.8	Changes in market circumstances 

 If at any time a Lender determines (which determination shall be final and conclusive and binding on the Borrower) that, by reason of changes affecting the London Interbank market, adequate and fair means
do not exist for ascertaining the rate of interest on the Loan or any part thereof pursuant to this Agreement: 
  

	13.8.1	that Lender shall give notice to the Agent and the Agent shall give notice to the Borrower of the occurrence of such event; and 

 

	13.8.2	the Agent shall as soon as reasonably practicable certify to the Borrower in writing the effective cost to that Lender of maintaining its Commitment for such further
period as shall be selected by that Lender and the rate of interest payable by the Borrower for that period; or, if that is not acceptable to the Borrower, 

 

	13.8.3	the Agent in accordance with instructions from that Lender and subject to that Lender’s approval of any agreement between the Agent and the Borrower, will
negotiate with the Borrower in good faith with a view to modifying this Agreement to provide a substitute basis for that Lender’s Commitment which is financially a substantial equivalent to the basis provided for in this Agreement.

 If, within thirty (30) days of the giving of the notice referred to in clause 13.8.1, the Borrower and the
Agent fail to agree in writing on a substitute basis for such Lender’s Commitment the Borrower will immediately prepay the amount of such Lender’s Commitment and the Maximum Loan Amount will automatically decrease by the amount of such
Commitment and such decrease shall not be reversed. Clause 5.4 shall apply to that prepayment if it is made on a day other than the last day of an Interest Period. 
  

	13.9	Non-availability of currency 

 If a Lender is for any reason unable to obtain Dollars in the London Interbank market and is, as a result, or as a result of any other contingency affecting the London Interbank market, unable to advance
or maintain its Commitment in Dollars, that Lender shall give notice to the Agent and the Agent shall give notice to the Borrower and that Lender’s obligations to make the Loan available shall immediately cease. In that event, if all or any
part of the Loan shall have been advanced by that Lender to the Borrower, the Agent in accordance with instructions from that Lender and subject to that Lender’s approval of any agreement between the Agent and the Borrower, will negotiate with
the Borrower in good faith with a view to establishing a mutually acceptable basis for funding the Loan or relevant part thereof from an alternative source. If the Agent and the Borrower have failed to agree in writing on a basis for funding the
Loan or relevant part thereof from an alternative source by 11.00 a.m. on the second Business Day prior to the end of the then current relevant Interest Period, the Borrower will (without prejudice to its other obligations under or pursuant to this
Agreement, including, without limitation, its obligation to pay interest on the Loan, arising on the expiry of the then relevant Interest Period) prepay the Lender Indebtedness (or relevant part thereof) to the Agent on behalf of that Lender on the
expiry of the then current relevant Interest Period. 
  

	13.10	Mitigation 

  

	13.10.1	Each Lender Finance Party shall, subject to clause 13.10.2 below, in consultation with the Borrower, take all reasonable steps to mitigate any circumstances which arise
and which would result in any amount becoming payable under or pursuant to, or cancelled pursuant to, any of clause 13.3, clause 13.6 or clause 13.7 including (but not limited to) transferring its rights and obligations under the Security Documents
to an Affiliate. 

  

	13.10.2	The Borrower shall indemnify each Lender Finance Party for all costs and expenses properly incurred by that Lender Finance Party as a result of steps taken by it under
clause 13.10.1. A Lender Finance Party is not obliged to take any steps under clause 13.10.1 if, in the opinion of that Lender Finance Party (acting reasonably), to do so might be prejudicial to it. 

  
 76 

	14	Communications 

  

	14.1	Method 

 Any
communication may be given, delivered, made or served (as the case may be) under or in relation to this Agreement by letter or fax or (subject to clause 14.3) electronic mail and shall be in the English language and sent addressed:- 

 

	14.1.1	in the case of any of the Lenders to the Agent at the address specified for BNP Paribas S.A. in Schedule 1; 

 

	14.1.2	in the case of the Agent, at the address specified for BNP Paribas S.A. in Schedule 1; 

 

	14.1.3	in the case of the Security Trustee, at the address specified for BNP Paribas S.A. in Schedule 1; 

 

	14.1.4	in the case of the KEIC Agent, at the address specified for BNP Paribas S.A. in Schedule 1 ; 

 

	14.1.5	in the case of the Borrower at: 

Mitsui & Co., Ltd. 
 2-1, Ohtemachi 1-chome, 
 Chiyoda-ku, 

Tokyo, 100-0004, 

Japan 
  

	 	Fax:	81-3-3285-9838 

  

	 	Attention:	General Manager, LNG Project Department, 

	 	    	Second Ship & Marine Project Division 

  

	 	Email:	tkmyj@dg.mitsui.com 

 or to such
other address or fax number as any of the above parties may designate for themselves by written notice to the others. 
  

	14.2	Timing 

 A Communication
shall be deemed to have been duly given, delivered, made or served to or on, and received by a party to this Agreement:- 
  

	14.2.1	in the case of a fax when the sender receives one or more transmission reports showing the whole of the Communication to have been transmitted to the correct fax
number; 

  

	14.2.2	if delivered to an officer of the relevant party or left at the address of the relevant party specified in clause 14.1; or 

 

	14.2.3	if posted, at 9.00 a.m. on the fifth Business Day after posting by prepaid first class post. PROVIDED ALWAYS that communications to the Agent and (to the extent that
they relate to the matters specified in clause 4.10.2 of the Intercreditor Deed only) the Lenders and the Borrower shall be effective only upon receipt; or 

 

	14.2.4	if by electronic mail, in accordance with clause 14.3; 

 Any Communication by fax shall be promptly confirmed in writing by post or hand delivery. 

  
 77 

	14.3	Electronic communication 

  

	14.3.1	Any communication to be made in connection with this Agreement may be made by electronic mail or other electronic means, if the Borrower and the relevant Lender Finance
Party: 

  

	 	(a)	agree that, unless and until notified to the contrary, this is to be an accepted form of communication; 

 

	 	(b)	notify each other in writing of their electronic mail address and/or any other information required to enable the sending and receipt of information by that means; and

  

	 	(c)	notify each other of any change to their address or any other such information supplied by them. 

 

	14.3.2	Any electronic communication made between the Borrower and the relevant Lender Finance Party will be effective only when actually received in readable form and
acknowledged by the recipient (it being understood that any system generated responses do not constitute an acknowledgement) and in the case of any electronic communication made by the Borrower to a Lender Finance Party only if it is addressed in
such a manner as the Lender Finance Party shall specify for this purpose. 

  

	14.3.3	Any electronic communication made in accordance with this clause 14.3 shall be confirmed in writing as soon as reasonably practicable thereafter.

  

	15	General Indemnities 

  

	15.1	Currency 

 In the event of
any Lender Finance Party receiving or recovering any amount payable under any of the Security Documents in a currency other than the Currency of Account, and if the amount received or recovered is insufficient when converted into the Currency of
Account at the date of receipt to satisfy in full the amount due, the Borrower shall, on the Agent’s written demand, pay to the Agent such further amount in the Currency of Account as is sufficient to satisfy in full the amount due and that
further amount shall be due to the Agent on behalf of the Lender Finance Parties as a separate debt under this Agreement. 
  

	15.2	Costs and expenses 

 The
Borrower will, on the earlier of (a) the date falling thirty (30) days from the date of the Agent’s written demand and (b) the date of the next following payment of charterhire under the Time Charter, reimburse the Agent (on
behalf of each of the Lender Finance Parties and KEIC) for all reasonable out of pocket expenses including internal and external legal costs (including stamp duty, Value Added Tax or any similar or replacement tax if applicable but excluding income
tax) of and incidental to:- 
  

	15.2.1	the negotiation, preparation, execution and registration of the Security Documents (whether or not any of the Security Documents are actually executed or registered and
whether or not all or any part of the Loan is advanced); 

  

	15.2.2	any amendments, addenda or supplements to any of the Security Documents (whether or not completed); 

 

	15.2.3	any other documents (including legal opinions) which may at any time be required by any Lender Finance Party to give effect to any of the Security Documents or which
any Lender Finance Party is entitled to call for or obtain pursuant to any of the Security Documents; and 

  

	15.2.4	without prejudice to clauses 15.3 and 15.5, the exercise of the rights, powers, discretions and remedies of the Lender Finance Parties under or pursuant to the Security
Documents. 

  
 78 

	15.3	Events of Default 

 The
Borrower shall indemnify the Lender Finance Parties from time to time on demand against all losses and costs incurred or sustained by any Lender Finance Party as a consequence of any Event of Default, including (without limitation) any Break Costs.

  

	15.4	Funding costs 

 The
Borrower shall indemnify the Lender Finance Parties from time to time on demand against all losses and costs incurred or sustained by any Lender Finance Party if, for any reason due to a Potential Event of Default or other action by the Borrower,
any Drawing is not advanced to the Borrower after the relevant Drawdown Notice has been given to the Agent, or is advanced on a date other than that requested in the Drawdown Notice, including (without limitation), any Break Costs. 

 

	15.5	Protection and enforcement 

  

	15.5.1	The Borrower shall indemnify the Lender Finance Parties and KEIC from time to time on demand against all losses, costs and liabilities which any Lender Finance Party or
KEIC may from time to time sustain, incur or become liable for in or about the protection, maintenance or enforcement of the rights conferred on the Lender Finance Parties and KEIC by the Security Documents or in or about the exercise or purported
exercise by the Lender Finance Parties or KEIC of any of the rights, powers, discretions or remedies vested in them under or arising out of the Security Documents, including (without limitation) any losses, costs and liabilities which any Lender
Finance Party or KEIC may from time to time sustain, incur or become liable for by reason of any Lender Finance or KEIC Party being mortgagees of the Vessel, assignees of any Mortgage and/or a Lender to the Borrower, or by reason of any Lender
Finance Party or KEIC being deemed by any court or authority to be an operator or controller, or in any way concerned in the operation or control, of the Vessel. No such indemnity will be given to a Lender Finance Party or KEIC where any such loss,
cost or liability has occurred due to wilful misconduct or recklessness with knowledge of the probable consequences on the part of that Lender Finance Party or KEIC; however this shall not affect the right of any other Lender Finance Party or KEIC
to receive any such indemnity. 

  

	15.5.2	The Agent shall: 

  

	 	(a)	notify the Borrower in writing of any claim made against it of which it is aware which is likely to give rise to such losses, costs and liabilities;

  

	 	(b)	unless an Event of Default has occurred and is continuing, consult, in good faith with the Borrower, in respect of such claim until such date as the Lender Finance
Party is obliged to satisfy or discharge such claim and not enter into any settlement or other compromise in respect of such claim without the prior written consent of the Borrower (which consent shall not be unreasonably withheld or delayed),
unless the Lender Finance Parties expressly waive in writing their right to be indemnified in respect of such losses, costs and liabilities; 

  

	 	(c)	so long as it is indemnified to its satisfaction against costs or liabilities that may be incurred, use reasonable endeavours to defend such claim and to avoid or
reduce the losses, costs and liabilities which may be incurred; and 

  

	 	(d)	unless an Event of Default has occurred and is continuing, give the Borrower a reasonable opportunity to take such action, at the Borrower’s cost, as the Borrower
deems fit to defend or avoid any liability being incurred or to take action against a third party in respect of any losses (provided that the Borrower may not take any action in the name of the Lender Finance Party without that Lender Finance
Party’s prior written consent nor may the Borrower take any action which would involve risk of criminal or civil liability to the Lender Finance Parties or any material risk of the sale, loss or forfeiture of the Vessel).

  
 79 

	15.5.3	The indemnities in this clause 15.5 shall not extend to any claim or liability of a Lender Finance Party to the extent that such claim or liability arises from an act
or omission on the part of that Lender Finance Party which constitutes gross negligence or wilful misconduct on the part of such Lender Finance Party. 

  

	15.6	Liabilities of Lender Finance Parties 

 The Borrower will from time to time reimburse the Lender Finance Parties on demand for all sums which any Lender Finance Party may pay on account of any of the Security Parties or in connection with the
Vessel (whether alone or jointly or jointly and severally with any other person) including (without limitation) all sums which any Lender Finance Party may pay or guarantees which any Lender Finance Party may give in respect of the Insurances, any
expenses incurred by any Lender Finance Party in connection with the maintenance or repair of the Vessel or in discharging any lien, bond or other claim relating in any way to the Vessel, and any sums which any Lender Finance Party may pay or
guarantees which they may give to procure the release of the Vessel from arrest or detention. 
  

	15.7	Taxes 

 The Borrower shall
pay all Taxes imposed on the Lender Finance Parties in respect of the Security Documents or to which all or any part of the Lender Indebtedness or any of the Security Documents or the Project Documents may be at any time subject and shall indemnify
the Lender Finance Parties on demand against all liabilities, costs, claims and expenses incurred in connection therewith, including but not limited to any such liabilities, costs, claims and expenses resulting from any omission to pay or delay in
paying any such Taxes. Provided that the indemnification in this clause 15.7 shall not apply to the extent that the Taxes imposed on a Lender Finance Party arose directly or indirectly from the gross negligence or wilful misconduct of such Lender
Finance Party. The indemnity contained in this clause 15.7 shall survive the repayment of the Lender Indebtedness. 
  

	15.8	Value Added Tax 

 All
amounts set out, or expressed to be payable by the Borrower to the Lender Finance Parties pursuant to the Security Documents which (in whole or in part) constitute consideration for a supply for Value Added Tax purposes shall be deemed to be
exclusive of any Value Added Tax which is chargeable on such supply, and accordingly, if Value Added Tax is chargeable on any supply made by any Lender Finance Party to a Borrower under a Security Document, that Borrower shall pay to the Lender
Finance Party (in addition to and at the same time as paying the consideration) an amount equal to the amount of the Value Added Tax. 
  

	15.9	KEIC Indemnity 

 The
Borrower shall indemnify the KEIC Agent and each Lender from time to time on demand against any duly evidenced additional premium, cost or expense as provided for under the KEIC Buyer Credit Policy, which KEIC may charge, invoice, or set-off against
amounts owing to the KEIC Agent and/or the Lenders, including without limitation as a result of a change of the delivery schedule of the Vessel, a change to Schedule 7 (Contract Instalments and Repayment Profile) of this Agreement or
otherwise, properly incurred by the KEIC Agent or a Lender in connection with their compliance with the KEIC Buyer Credit Policy. 
  

	16	Miscellaneous  

  

	16.1	Tax Lease 

  

	16.1.1	The Lender Finance Parties agree that the Loan may be refinanced to incorporate a lease financing structure with the prior written consent of each Lender Finance Party.
Each Lender Finance Party agrees that it shall not unreasonably withhold or delay its consent to the implementation of a lease financing structure, provided that: 

 

	 	(a)	it is satisfied that its security position will not be materially and adversely affected; 

  
 80 

	 	(b)	it has received agreed and executed documentation acceptable to it in all respects; 

 

	 	(c)	the lease financing structure is not, in its reasonable opinion, unduly onerous in terms of documentation and time; 

 

	 	(d)	it has received credit approval for such lease financing; and 

  

	 	(e)	it has received legal opinions satisfactory to it in relation to jurisdictions reasonably required by it. 

 

	16.1.2	No Lender Finance Party shall be entitled to any additional fees from the Borrower in connection with the implementation of a lease financing structure.

  

	16.1.3	The Borrower shall pay the reasonable costs and expenses (including, without limitation, the reasonable fees and expenses of outside legal counsel engaged by the Lender
Finance Parties) incurred by the Lender Finance Parties in connection with the implementation of the lease finance structure. 

  

	16.2	Waivers 

 No failure or
delay on the part of any Lender Finance Party in exercising any right, power, discretion or remedy under or pursuant to any of the Security Documents, nor any actual or alleged course of dealing between any Lender Finance Party and any of the
Security Parties, shall operate as a waiver of, or acquiescence in, any default on the part of any Security Party, unless expressly agreed to do so in writing by the Agent, nor shall any single or partial exercise by any Lender Finance Party of any
right, power, discretion or remedy preclude any other or further exercise of that right, power, discretion or remedy, or the exercise by a Lender Finance Party of any other right, power, discretion or remedy. 

 

	16.3	No variations 

 No
variation or amendment of any of the Security Documents shall be valid unless made by each party thereto and in accordance with the terms thereof and consented to in writing by KEIC. 

 

	16.4	Severability 

 If at any
time any provision of any of the Security Documents is invalid, illegal or unenforceable in any respect that provision shall be severed from the remainder and the validity, legality and enforceability of the remaining provisions shall not be
affected or impaired in any way. 
  

	16.5	Successors etc. 

 The
Security Documents shall be binding on the Security Parties and on their successors and permitted transferees and assignees, and shall inure to the benefit of the Lender Finance Parties and KEIC in respect of their rights and their respective
successors, transferees and assignees. 
  

	16.6	Further assurance 

 If any
provision of the Security Documents shall be invalid or unenforceable in whole or in part by reason of any present or future law or any decision of any court, then from time to time the Borrower will promptly, following a demand by the Agent,
execute or procure the execution of such further documents as in the reasonable opinion of the Lenders are necessary to provide valid and enforceable security for the repayment of the Lender Indebtedness, provided that with respect to any further
document relating to the Time Charter, the Borrower shall only be required to procure the execution of such documents on a reasonable endeavours basis. 

  
 81 

	16.7	Other arrangements 

 The
Lender Finance Parties may, without prejudice to their rights under or pursuant to the Security Documents, at any time and from time to time, on such terms and conditions as they may in their discretion determine, and with notice to the Borrower,
grant time or other indulgence to, or compound with, any other person liable (actually or contingently) to the Lender Finance Parties or any of them in respect of all or any part of the Lender Indebtedness, and may release or renew negotiable
instruments and take and release securities and hold funds on realisation or suspense account without affecting the liabilities of the Borrower or the rights of the Lender Finance Parties under or pursuant to the Security Documents. 

 

	16.8	Advisers 

 The Borrower
irrevocably authorises the Agent, at any time and from time to time during the Facility Period, to consult insurance advisers on any matters relating to the Insurances, including, without limitation, the collection of insurance claims, and from time
to time to consult or retain advisers or consultants to monitor or advise on any other claims relating to the Vessel. Subject to clause 9.1.22 the Borrower will provide such advisers and consultants with all information and documents which they may
from time to time reasonably require. In the event that such advisers or consultants discover that the Borrower is in breach of its obligations in relation to the Insurances or at the time of or during such consultation or retention there occurs an
Event of Default which is continuing unremedied or unwaived, then the Borrower will reimburse the Agent on demand for all reasonable costs and expenses properly incurred by the Agent in connection with the consultation or retention of such advisers
or consultants, but such consultation or retention shall otherwise be at the Lender Finance Parties’ own cost and expense. 
  

	16.9	Delegation 

 The Lender
Finance Parties may at any time and from time to time delegate to any person any of their rights, powers, discretions and remedies pursuant to the Security Documents, other than rights relating to actions to be taken by the Majority Lenders or the
Lenders as a group, on such terms as they may consider appropriate (including the power to sub-delegate). 
  

	16.10	Rights etc. cumulative 

Every right, power, discretion and remedy conferred on the Lender Finance Parties under or pursuant to the Security Documents shall be
cumulative and in addition to every other right, power, discretion or remedy to which they may at any time be entitled by law or in equity. The Lender Finance Parties may exercise each of their rights, powers, discretions and remedies as often and
in such order as they deem appropriate subject to obtaining the prior written consent of the Majority Lenders. The exercise or the beginning of the exercise of any right, power, discretion or remedy shall not be interpreted as a waiver of the right
to exercise any other right, power, discretion or remedy either simultaneously or subsequently. 
  

	16.11	No enquiry 

 The Lender
Finance Parties shall not be concerned to enquire into the powers of the Security Parties or of any person purporting to act on behalf of any of the Security Parties, even if any of the Security Parties or any such person shall have acted in excess
of their powers or if their actions shall have been irregular, defective or informal, whether or not any Lender Finance Parties had notice thereof. 
  

	16.12	Continuing security 

 The
security constituted by the Security Documents shall be continuing and shall not be satisfied by any intermediate payment or satisfaction until the Indebtedness shall have been repaid in full and none of the Lender Finance Parties shall be under any
further actual or contingent liability to any third party in relation to the Vessel, the Insurances, Earnings or Requisition Compensation or any other matter referred to in the Security Documents. 

  
 82 

	16.13	Security cumulative 

 The
security constituted by the Security Documents shall be in addition to any other security now or in the future held by the Lender Finance Parties or any of them for or in respect of all or any part of the Lender Indebtedness, and shall not merge
with or prejudice or be prejudiced by any such security or any other contractual or legal rights of any of the Lender Finance Parties, nor affected by any irregularity, defect or informality, or by any release, exchange or variation of any such
security. Section 93 of the Law of Property Act 1925 and all provisions which the Agent considers analogous thereto under the law of any other relevant jurisdiction shall not apply to the security constituted by the Security Documents.

  

	16.14	No liability 

 None of the
Lender Finance Parties, nor any agent or employee of any Lender Finance Party, nor any receiver and/or manager appointed by the Agent, shall be liable for any losses which may be incurred in or about the exercise of any of the rights, powers,
discretions or remedies of the Lender Finance Parties under or pursuant to the Security Documents nor liable as mortgagee in possession for any loss on realisation or for any neglect or default of any nature for which a mortgagee in possession might
otherwise be liable unless such Lender Finance Party’s action constitutes wilful misconduct or recklessness with knowledge of the probable consequences. 
  

	16.15	Rescission of payments etc. 

 Any discharge, release or reassignment by any of the Lender Finance Parties of any of the security constituted by, or any of the obligations of any Security Party contained in, any of the Security
Documents shall be (and be deemed always to have been) void if any act (including, without limitation, any payment) as a result of which such discharge, release or reassignment was given or made is subsequently wholly or partially rescinded or
avoided by operation of any law, unless such Lender Finance Party’s action constitutes wilful misconduct or recklessness with knowledge of the probable consequences. 

 

	16.16	Subsequent Encumbrances 

If the Agent receives notice of any subsequent Encumbrance (other than any Permitted Encumbrance) affecting the Vessel or all or any part
of the Insurances, Earnings or Requisition Compensation, the Agent may open a new account in its books for the Borrower. If the Agent does not open a new account, then (unless the Encumbrance is a Permitted Encumbrance or the Agent gives written
notice to the contrary to the Borrower) as from the time of receipt by the Agent of notice of such subsequent Encumbrance, all payments made to the Agent shall be treated as having been credited to a new account of the Borrower and not as having
been applied in reduction of the Lender Indebtedness. 
  

	16.17	Releases 

 If any Lender
Finance Party shall at any time in its discretion release any party from all or any part of any of the Security Documents or from any term, covenant, clause, condition or obligation contained in any of the Security Documents, the liability of any
other party to the Security Documents shall not be varied or diminished. 
  

	16.18	Certificates 

 Any
certificate or statement signed by an authorised signatory of the Agent purporting to show the amount of the Lender Indebtedness (or any part of the Lender Indebtedness) or any other amount referred to in any of the Security Documents shall, save
for manifest error or on any question of law, be conclusive evidence as against the Borrower of that amount. 

  
 83 

	16.19	Survival of representations and warranties 

 The representations and warranties on the part of the Borrower contained in this Agreement shall survive the execution of this Agreement and the advance of the Loan or any part thereof. 

 

	16.20	Counterparts 

 This
Agreement may be executed in any number of counterparts each of which shall be original but which shall together constitute the same instrument. 
  

	16.21	Third Party Rights 

Notwithstanding the provisions of the Contracts (Rights of Third Parties) Act 1999, no term of this Agreement is enforceable by a person
who is not a party to it other than (a) KEIC in respect of its rights under this Agreement and (b) the Account Bank in respect of its rights under clause 7.5. 
  

	16.22	Building Contract Disputes 

The Borrower acknowledges and agrees that its obligations under this Agreement are independent from the Building Contract and that the
performance of these obligations shall in no event be affected by any dispute whatsoever that may arise between the Builder and the Borrower in relation to the Building Contract or in any other respect. 

 

	16.23	Confidentiality 

 At all
times during the Facility Period, the Borrower shall keep confidential any Confidential Information (as defined below) relating to the Relevant Documents (other than the Project Documents) and each of the Lender Finance Parties shall keep
confidential any Confidential Information (as defined below) relating to the Relevant Documents, and none of the Borrower or the Lender Finance Parties shall, without the prior written consent of the other(s): 

 

	16.23.1	issue any press release or make any other public announcement or statement in relation to the transactions evidenced by this Agreement and the other Relevant Documents;
or 

  

	16.23.2	disclose to any other person (i) any information or document relating to the Angola LNG Project in general, including but not limited to, technical and schedule
requirements, and progress and status of the Angola LNG Project; (ii) financial details of this Agreement or any other Relevant Document or the transactions contemplated by this Agreement or any other Relevant Document or any other agreement
after the date of this Agreement by the Borrower or the Lender Finance Parties in connection with this Agreement or any other Relevant Document or (iii) any information provided pursuant to any of the Relevant Documents; or

  

	16.23.3	release copies of drafts of this Agreement or any other Relevant Document which disclose or reveal the identity of the parties (or any of them),

 the information contemplated by clauses 16.23.1 to 16.23.3 above being “Confidential
Information”. 
 Provided that notwithstanding the foregoing provisions of this clause 16.22 the parties shall be
entitled, without any such consent, to disclose such Confidential Information: 
  

	 	(a)	if the same is already known to the receiving person at the time of disclosure as shown by the receiving person’s files and records immediately prior to that
disclosure or is developed by the receiving person independently of such disclosure; or 

  

	 	(b)	in connection with any proceedings arising out of or in connection with this Agreement or any of the other Relevant Documents; or 

  
 84 

	 	(c)	if required to do so by an order of a court of competent jurisdiction whether in pursuance of any procedure for discovery of documents or otherwise; or

  

	 	(d)	pursuant to any applicable law, stock exchange regulations or by a governmental order, decree, regulation or rule, provided however that a party which has received
Confidential Information which they are obliged to disclose as contemplated by this clause (d) shall use reasonable efforts to inform the person who provided them with the Confidential Information prior to making such disclosure; or

  

	 	(e)	to any fiscal, monetary, tax, governmental or other competent authority; or 

 

	 	(f)	to the auditors, legal or professional or insurance advisors, underwriters or brokers of the Borrower or the relevant Lender Finance Party, who (A) shall have a
need to have such knowledge of the same in connection with carrying out work related to the transaction contemplated by this Agreement and the other Relevant Documents and (B) shall be advised of the confidential nature of any such information
supplied to them and shall be instructed to maintain the confidentiality of any information supplied to them; or 

  

	 	(g)	in any manner contemplated by any of the Relevant Documents; or 

  

	 	(h)	if the same is in the public domain or shall become publicly known otherwise than as a result of a breach by such party or by the receiving person or any other person
to whom disclosure is made of this clause 16.23.1; or 

  

	 	(i)	if the same is acquired independently from a third party without breach of that third party’s obligations of confidentiality; or 

 

	 	(j)	in the case of the Borrower, to any Borrower Shareholder or Sponsor or the Time Charterer, to the extent the Borrower reasonably believes necessary for the purpose of
the Time Charterer to perform, fulfil its obligations or exercise its rights in accordance with the terms of the Time ChartererCharter, or to any member of the Time
Charterer, any of such member’s affiliates, and their respective directors, officers, employees or contractors in each case to the extent the Borrower reasonably believes necessary for the performance of the Security Documents and/or the
Project Documents, and in the case of the Lender Finance Parties, to any member of their respective groups or any potential transferee, assignee, successor, any rating agency or any financial institutions, special purpose securitisation vehicles
and their managements, all investors, agents, arrangers, dealers who are or might wish to be involved in securitisation schemes, hedging agreements, participation or other risk transfer
agreements (or any directors, officers or employee of the foregoing), provided that in each case the Borrower or the Lender Finance Party shall procure that the party to whom such
disclosure is made shall comply with the requirements of this clause and provided further that the Lender Finance Parties shall not disclose any information regarding the Angola LNG Project to any of the foregoing persons except to a member of their
respective groups, any potential transferee, assignee, successor or financial institution on a need-to-know basis and solely for carrying out the purpose of and exercising their rights under this Agreement and the other Security Documents; or

  

	 	(k)	to KEIC, 

 provided that if the
Confidential Information is provided by a party on the basis that it is to be kept confidential, but the party providing the information discloses it to another person on a non-confidential basis, then the receiving party or parties shall no longer
be obliged to treat such information as confidential. 
  

	16.23.4	The Borrower and the Lender Finance Parties shall be responsible for ensuring that where Confidential Information is disclosed to persons under clause 16.23.3 such
persons shall keep the information confidential in accordance with and subject to this clause 16.23. 

  
 85 

	17	Law and Jurisdiction 

  

	17.1	Governing law 

 This
Agreement shall in all respects be governed by and interpreted in accordance with English law. 
  

	17.2	Jurisdiction 

 For the
exclusive benefit of the Lender Finance Parties, the parties to this Agreement irrevocably agree that the English courts are to have jurisdiction to settle any disputes which may arise out of or in connection with this Agreement and that any legal
actions or proceedings may be brought in those courts. The Borrower irrevocably waives any objection which it may now or in the future have to the laying of the venue of any legal actions or proceedings in any court referred to in this clause 17.2,
and any claim that such legal actions or proceedings have been brought in an inconvenient or inappropriate forum. The Borrower irrevocably and unconditionally submits to the jurisdiction of such courts and shall within five (5) Business Days of
the date hereof irrevocably designate, appoint and empower an agent to receive for it and on its behalf, service of process issued out of the English courts in any such legal actions or proceedings and shall provide the Facility
Agent with details of such agent. The submission to such jurisdiction shall not (and shall not be construed so as to) limit the right of any of the Lender Finance Parties to take legal actions or proceedings against the Borrower in the courts of any
other competent jurisdiction nor shall the taking of legal actions or proceedings in any one or more jurisdictions preclude the taking of legal actions or proceedings in other jurisdiction, whether concurrently or not. 

The parties further agree that only the courts of England and not those of any other state or jurisdiction shall have jurisdiction to
determine any claim which the Borrower may have against any of the Lender Finance Parties arising out of or in connection with this Agreement. 

IN WITNESS of which the parties to this Agreement have executed this Agreement the day and year first before written. 

  
 86 

 Schedule 1 
 Part I: The Lenders, the Commitments and the Proportionate Shares 
 Part
1: the Lenders 
  

											
	 The Lenders
	  	Contact Details	  	Commitments	 
	  	  	Buyer Credit	 	  	Commercial Loan	 
		  	For commercial matters:	  				  			
		  	CIB - Transportation Group	  				  			
		  	16 rue de Hanovre	  				  			
		  	75078 Paris Cedex 02 - France	  				  			
		  	Fax no. +33 1 42 98 43 55	  				  			
		  	  
 Attention: Shipping Finance
	  				  			
		  	Alice Renaudin Durand-Ruel	  				  			
		  	  
 For Security Trustee matters:
	  				  			
		  	CIB - Transportation Group	  				  			
		  	16 rue de Hanovre	  				  			
		  	75078 Paris Cedex 02 - France	  				  			
		  	Fax no. +33 1 42 98 43 55	  				  			
		  	  

Attention: Shipping Asset Monitoring
	  				  			
		  	Jean-Marc Morant	  				  			
	 BNP Paribas S.A.
	  	  
 For Agency matters:
	  	$	15,400,000	  	  	$	19,600,000	  
		  	CIB - Agency - European Group	  				  			
		  	21 Place du Marche Saint Honore	  				  			
		  	75031 Paris Cedex 01 - CHA02A1	  				  			
		  	Fax no. +33 1 42 98 43 17	  				  			
		  	  
 Attention: European Group
	  				  			
		  	Claire-Marie Rochette	  				  			
		  	  
 For KEIC Agent matters:
	  				  			
		  	BNP Paribas S.A., Seoul Branch	  				  			
		  	24/F, Taepyeongno 2-ga, Jung-gu	  				  			
		  	Seoul 100-767 Korea	  				  			
		  	Fax no. 82 2 757 2530	  				  			
		  	  

Attention: Jae Seung /
Myung Shim Kwon
	  				  			

  
 87 

											
	 The Lenders
	  	Contact Details	  	Commitments	 
	  	  	Buyer Credit	 	  	Commercial Loan	 
		  	For administration matters:	  				  			
		  	9 Quai, du President Paul Doumer	  				  			
		  	92920 Paris La Défence Cédex	  				  			
		  	France	  				  			
		  	  
 Fax no: +33 141 89 19 34
	  				  			
		  	Attention: Middle Office/Shipping/	  				  			
		  	Ms Marie-claire Vanderperre/	  				  			
		  	M. Godet-Couery	  				  			
	 Calyon
	  		  	$	15,400,000	  	  	$	19,600,000	  
		  	For credit matters:	  				  			
		  	Broadwalk House	  				  			
		  	5 Appold Street	  				  			
		  	London	  				  			
		  	EC2A 2DA	  				  			
		  	  
 Fax no: +44 207 214 6689
	  				  			
		  	Attention: Thibaud Escoffier/Jerome
Duval	  				  			
		  	For administrative matters:	  				  			
		  	20 St. Dunstan’s Hill	  				  			
		  	London	  				  			
		  	EC3R 8HY	  				  			
		  	  
 Fax no. +44 207 283 4430
	  				  			
		  	Attention: Loans Administration	  				  			
		  	Mr Renato Mariano	  				  			
	 DnB NOR Bank ASA
	  		  	$	15,400,000	  	  	$	19,600,000	  
		  	For credit matters:	  				  			
		  	20 St. Dunstan’s Hill	  				  			
		  	London	  				  			
		  	EC3R 8HY	  				  			
		  	  
 Fax no. +44 207 626 5956
	  				  			
		  	Attention: Omar Sekkat and David	  				  			
		  	Grant	  				  			

  
 88 

											
	 The Lenders
	  	Contact Details	 	Commitments	 
	  	 	Buyer Credit	 	  	Commercial Loan	 
		  	For operational matters:	 				  			
		  	OPER / CAF / DMT6	 				  			
		  	17 Cours Valmy	 				  			
		  	Paris La Defense 7	 				  			
		  	  
 Fax no. +331 46 92 45 98
	 				  			
		  	Attention: Viengkham LAY and	 				  			
		  	Chantal Alcaras	 				  			
	 Société Générale,
	  	  
 For credit matters:
	 	$	15,400,000	  	  	$	19,600,000	  
		  	SG House	 				  			
		  	41 Tower Hill	 				  			
		  	London	 				  			
		  	EC3N 4SG	 				  			
		  	  
 Fax no. +44 207 667 2499

Attention: Gareth-Lon Williams
	 				  			
		  	Copy to: Pierre Baud and Laurence	 				  			
		  	Alloiteau	 				  			
		  	OPER/CAF/AFI	 				  			
		  	17 Cours Valmy	 				  			
		  	Paris La Défence 7	 				  			
		  	  
 Fax no. 01.46.92.46.22
	 				  			
		  	  
 Copy to: Guylaine Labidurie
	 				  			
		  	OPER/CAF.EXT	 				  			
		  	  
 Fax no. 01.46.92.45.97
	 				  			
		  	For operational matters:	 				  			
		  	99 Queen Victoria Street	 				  			
		  	London	 				  			
		  	EC4V 4EH	 				  			
		  	  
 Fax no. +44 207 786 1569
	 				  			
		  	Attention: David Griffiths/Jo Dunnage	 				  			
		  	  
 For credit matters:
	 				  			
		  	99 Queen Victoria Street	 				  			
		  	London	 				  			
		  	EC4V 4EH	 				  			
	 Sumitomo Mitsui Banking Corporation,

     Brussels Branch
	  	  
 Fax no. +44 207 786 101

Attention: Robert Taylor/Cyrille Martin
	 	$	15,400,000	  	  	$	19,600,000	  
		  	  
 Copy to: Guillaume Dufour/Touf-itri
	 				  			
		  	Akdime	 				  			
		  	20 rue de la Ville I’evêque	 				  			
		  	75008 Paris	 				  			
		  	  
 Fax no. +33 1 44 71 40 50
	 				  			
		  	  
 Copy to: Françoise Bouchat/Nadine
	 				  			
		  	Boudart	 				  			
		  	Avenue des Arts 58,	 				  			
		  	Box 18	 				  			
		  	1000 Brussels	 				  			
		  	Belgium	 				  			
		  	  
 Fax no. +32 2 502 07 80
	 				  			

  
 89 

											
	 The Lenders
	  	Contact Details	  	Commitments	 
	  	  	Buyer Credit	 	  	Commercial Loan	 
		  	For administrative matters:	  				  			
		  	12-15 Finsbury Circus
 London
	  				  			
		  	EC2M 7BT  

Fax no. +44 207 577 1559
	  				  			
		  	Attention: Daniel Bryan	  				  			
	 The Bank of Tokyo - Mitsubishi UFJ, Ltd.
	  	  
 For credit matters:
	  	$	15,400,000	  	  	$	19,600,000	  
		  	12-15 Finsbury Circus
London	  				  			
		  	EC2M 7BT	  				  			
		  	  
 Fax no. +44 207 577 1755
	  				  			
		  	Attention: Grahame Hunt	  				  			
		  		  	$	92,400,000	  	  	$	117,600,000	  

  
 90 

 Part 2: 
 the Swap Providers 
  

			
	 The Lenders
	  	 Contact Details

		  	 For commercial matters:
 CIB - Transportation Group
 16 rue de Hanovre

75078 Paris Cedex 02 - France
 Fax no. +33 1 42
98 43 55

		
		  	 Attention: Shipping Finance

Alice Renaudin Durand-Ruel

		
		  	 For Security Trustee matters:
 CIB - Transportation Group
 16 rue de Hanovre

75078 Paris Cedex 02 - France
 Fax no. +33 1 42
98 43 55
  
 Attention: Shipping Asset Monitoring

Jean-Marc Morant

		
	 BNP Paribas S.A.
	  	 For Agency matters:

CIB - Agency - European Group
 21 Place du Marche
Saint Honore
 75031 Paris Cedex 01 - CHA02A1
 Fax no. +33 1 42 98 43 17

		
		  	 Attention: European Group

Claire-Marie Rochette

		
		  	 For KEIC Agent matters:
 BNP Paribas S.A., Seoul Branch
 24/F, Taepyeongno 2-ga, Jung-gu

Seoul 100-767 Korea
 Fax no. 82 2 757
2530

		
		  	Attention: Jae Seung / Myung Shim Kwon

  
 91 

			
	 The Lenders
	  	 Contact Details

		  	For administration matters:
		  	9 Quai, du President Paul Doumer
		  	92920 Paris La Défence Cédex France
		
		  	Fax no: +33 141 89 19 34
		  	Attention: Middle Office/Shipping/
		  	Ms Marie-Claire Vanderperre/
		  	M. Godet-Couery
	 Calyon
	  	
		  	For credit matters:
		  	Broadwalk House
		  	5 Appold Street
		  	London
		  	EC2A 2DA
		
		  	Fax no: +44 207 214 6689
		  	Attention: Thibaud Escoffier/Jerome Duval
		
		  	For administrative matters:
		  	20 St. Dunstan’s Hill
		  	London
		  	EC3R 8HY
		
		  	Fax no. +44 207 283 4430
		  	Attention: Loans Administration
		  	Mr Renato Mariano
	 DnB NOR Bank ASA
	  	
		  	For credit matters:
		  	20 St. Dunstan’s Hill
		  	London
		  	EC3R 8HY
		
		  	Fax no. +44 207 626 5956
		  	Attention: Omar Sekkat and David Grant
		
		  	For operational matters
		  	OPER / CAF / DMT6
		  	17 Cours Valmy
		  	Paris La Defense 7
		
		  	Fax no. +331 46 92 45 98
		  	Attention: Viengkham LAY and
		  	Chantal Alcaras
		
	 Société Générale,
	  	For credit matters
		  	London
		
		  	Fax no. +44 207 667 2499
		  	Attention: Gareth-Lon Williams
		
		  	Copy to: Pierre Baud and Laurence Alloiteau
		  	OPER/CAF/AFI
		  	17 Cours Valmy

  
 92 

			
	 The Lenders
	  	 Contact Details

		  	 Paris La Défence 7
  

Fax no. 01.46.92.46.22

		
		  	Copy to: Guylaine Labidurie
		  	OPER/CAF.EXT
		
		  	Fax no. 01.46.92.45.97
		
		  	277 Park Avenue
		  	Fifth Floor
	 SMBC Capital Markets, Inc.
	  	New York
		  	10172
		  	USA
		
		  	Attention: President
		  	Fax no. (212)224-4948
		
		  	For administrative matters:
		  	12-15 Finsbury Circus
		  	London
		  	EC2M 7BT
		
		  	Fax no. +44 207 577 1559
		  	Attention: Daniel Bryan
		
	 The Bank of Tokyo-Mitsubishi UFJ, Ltd.
	  	For credit matters;
		  	12-15 Finsbury Circus
		  	London
		  	EC2M 7BT
		
		  	Fax no. +44 207 577 1755
		  	Attention: Grahame Hunt

  
 93 

 Schedule 2 
 The Vessel 
  

							
	Owner	  	Hull No	  	Flag	  	Vessel Type
	 MiNT IIIII LNG Ltd
	  	1812 at Samsung	  	Bahamas	  	160,000 cubic meter single
		  	Heavy Industries Co. Ltd.	  		  	screw electric motor driven
		  		  		  	liquefied natural gas carrier

  
 94 

 Schedule 3 
 Documents and evidence required as conditions precedent 
 (referred to in
clause 3.1) 
 Part I1: Commitment and first Drawing

	(a)	Constitutional documents 

  

	 	(i)	copies, certified by an officer of each Security
Partythe Borrower, NYK LNG and Teekay as true, complete and up to date copies of all documents which contain or establish the constitution of that Security
Partyit including the Articles of Incorporation; or 

 

	 	(ii)	with respect to Mitsui and NYK, in lieu of
the document described in clause (a)(i) above, a certified copy of the current Commercial Register (genzai jiko zenbu shomeisho) of Mitsui and NYK issued by the Tokyo Legal Affairs Bureau no earlier than 10 days prior to the date of this
Agreement. 

  

	(b)	Corporate authorisationsauthorizations 

 

	 	(i)	copies of resolutions of the directors and/or such other corporate approvals or authorisations and, to
the extent required to obtain any opinion set out in this Schedule 3, Part 1, the shareholders of each Security Partythe Borrower, NYK LNG and Teekay approving such of
the Project Documents (with respect to the Borrower only) and the Security Documents to which it is, or is to be, party and authorising the signature, delivery and performance of its
obligations thereunder, certified (in a certificate dated no earlier than 10 Business Days prior to the date of this Agreement) by an officer of it as: 

  

	 	1.	(i) being true and correct; 

  

	 	2.	(ii) being duly passed by the directors or such other persons as permitted by the organisational documents of such Security
Partyit and (if necessary) shareholders of such Security Partyit; 

 

	 	3.	(iii) not having been amended, modified or revoked; and 

 

	 	4.	(iv) being in full force and effect, 

 together with originals or certified copies of any powers of attorney issued by it pursuant to such resolutions; or 

 

	 	(ii)	with respect to Mitsui and NYK, in lieu of the document described in clause (b)(i) above (1) a power of
attorney, executed using the registered seal of the president or representative director of Mitsui or NYK, authorizing the signatory or signatories of the Security Documents to which Mitsui or NYK is a party to execute such documents on behalf of
Mitsui or NYK; and (2) a seal certificate (inkan shoumei), issued by the Tokyo Legal Affairs Bureau no earlier than 10 days prior to the date of this Agreement, in respect of the registered seal used to execute the power of attorney
described in clause (b)(ii)(2). 

  

	(c)	Specimen signatures 

copies of the signatures of the persons who have been authorised on behalf of each Security Party to sign such of the
ProjectSecurity Documents referred to in paragraph (g)of this Schedule 3, part 1 and the Security Documents referred to in paragraph (h) of this Schedule
3, part 1 to which such Security Party is, or is to be, party and to give notices and communications, including notices of drawing, under or in connection with the Security Documents, certified (in a certificate dated no earlier than 10 Business
Days prior to the date of this Agreement) by an officer or such other authorised persons of such Security Party as being the true signatures of such persons; 

  
 95 

	(d)	Certificates of incumbency; 

a list of directors and officers of the Borrower,
the Borrower Shareholders and the Sponsorsspecifying the names and positions of such persons, certified (in a certificate dated no earlier than 10 Business Days prior to the date of this Agreement) by an officer or such other
authorised person of it to be true, complete and up to date; 
  

	(e)	Time Charterer’s consents and approvals 

 evidence in a form and substance acceptable to the Agent that the Time Charterer shall have consented (so far as may be necessary) to the execution of the Mortgage, the Deed of Covenants, the Deed of
Assignment of Contracts and the Deed of Assignment of Building Contract and Refund Guarantee and other necessary documents hereunder in accordance with the Time Charter; 

 

	(f)	Certified Project Documents 

 a copy, certified (in a certificate dated no earlier than 5 Business Days prior to the date of this Agreement) as a true and complete copy by an officer of the Borrower of each of the Project Documents
(other than the Management Agreement) each duly executed and in a form and substance acceptable in all respects to the Agent together with the original executed copies of the Refund Guarantee; 

 

	(g)	Security Documents and Fee Letters 

 the Swap Agreements, any other Credit Support Documents, the Deed of Assignment of Contracts, the Assignment, the Deed of Assignment of Building Contract and Refund Guarantee, the Account Charge, the
Sponsors’ Undertaking, the Arrangement Fee Letter, the Agency Fee Letter, the Account Bank Fee Letter, the Documentation Agency Fee Letter and the Swap Margin Side Letter each duly executed; 

 

	(h)	Notices of assignment and acknowledgements 

 the Building Contract Assignment Consent and Acknowledgement, the Refund Guarantee Assignment Consent and Acknowledgement,
and the Supervision Agreement Consent and Acknowledgement, the Management Agreement Consent and Acknowledgement duly executed and bearing formal date stamps and
originals of duly executed notices of assignment together with original duly executed acknowledgements thereof (to be delivered on the first Drawdown Date) required by the terms of the Deed of Assignment of Contracts and the Deed of Assignment of
Building Contract and Refund Guarantee respectively in the forms prescribed by such Security Documents; 
  

	(i)	Share PledgesCharges 

(i) the Share PledgesCharges duly executed by all parties
thereto (other than the Security Trustee) and all requirements thereunder fully satisfied including, without limitation, the delivery of the Borrower’s share certificates and all irrevocable proxies to the Security Trustee; 

 

	(j)	Accounts 

 evidence that
the Accounts have been opened; 
  

	(k)	Bahamas opinion 

 opinions
(addressed to the Agent and KEIC) of the Agent’s special legal advisers in the Bahamas to the Agent prior to the first Drawing in form and substance satisfactory to the Lenders to be delivered on the first Drawdown Date; 

  
 96 

	(I)	Delaware opinion 

 opinion
(addressed to the Agent and KEIC) of special legal advisers in the State of Delaware in relation to (a) the due authorisation, execution, delivery and performance of the Time Charter, the Tripartite Agreement, the Angolanisation Agreement, the
Project Co-ordination Agreement and the Depot Spares Sharing Agreement by the Time Charterer and such documents constituting the legal, valid and binding obligations of the Time
Charterer, (b) the execution, delivery and performance of the Time Charter, the Tripartite Agreement, the Angolanisation Agreement, the Project
Co-ordination Agreement and the Depot Spares Sharing Agreement by the Time Charterer not conflicting with Delaware law and (c) the execution, delivery and performance of the Time Charter by the Time Charterer not conflicting with its
constitutional documents to be received prior to the first Drawing in form and substance satisfactory to the Lenders to be delivered on the first Drawdown Date; 
  

	(m)	Korean opinion 

 opinions
(addressed to the Agent and KEIC) of Kim & Chang special legal advisers in Korea to the Agent and KEIC Agent prior to the first Drawing in form and substance satisfactory to the Lenders to be delivered on the first Drawdown Date;

  

	(n)	Japanese opinion 

opinions (addressed to the Agent and KEIC) of Nishimura & Asahi special legal advisers in Japan to the Agent prior to the first
Drawing in form and substance satisfactory to the Lenders to be delivered on the first Drawdown Date; 
  

	(o)	Marshall Islands opinion 

opinions (addressed to the Agent and KEIC) of the Agent’s special legal advisors in the Marshall Islands to the Agent prior to the
first Drawing in form and substance satisfactory to the Lenders to be delivered on the first Drawdown Date; 
  

	(p)	English opinion 

 opinion
of Norton Rose LLP special legal advisors in England to the Agent prior to the first Drawing in form and substance satisfactory to KEIC to be delivered on the first Drawdown Date; 

 

	(q)	Further opinions/report 

(ii) an opinion from Norton Rose as to the legality, validity and enforceability of the Security Documents so far as they are governed by
the laws of England and Wales and in a form and substance acceptable in all respects to the Agent; 
  

	(r)	Borrower’s process agent 

 a copy, certified as a true copy by the Borrower’s solicitors or other person acceptable to the Agent of a letter from the Borrower’s agent for receipt of service of proceedings referred to in
clause 17.2 accepting its appointment under the said clause and under each of the other Security Documents in which it is or is to be appointed as the Borrower’s agent; 

 

	(s)	Process agent 

 a copy,
certified as a true copy by the Borrower’s solicitors or other person acceptable to the Agent of a letter from the Sponsors’ and any other Security Party’s agent for receipt of service of proceedings accepting its appointment under
each of the relevant Security Documents in which it is or is to be appointed as the Sponsors’ or such Security Party’s agent; 

  
 97 

	(t)	Drawdown Notice 

 the
Drawdown Notice in respect of the first Drawing duly executed and delivered in accordance with clause 2 of this Agreement; 
  

	(u)	Minimum Borrower Shareholders’ Equity / Additional Shareholders’ Equity 

receipt of the Relevant Amount of the Minimum Borrower Shareholders’ Equity and/or Additional Shareholders’ Equity by the
Borrower or the Agent in accordance with clause 2.3.7 and, insofar as such Relevant Amount is Indebtedness of the Borrower, any subordination agreement required by the Agent in form and substance satisfactory to the Agent (acting on the instructions
of all Lenders) in connection therewith; 
  

	(v)	Minimum Credit Rating 

evidence from either Standard and Poors or Fitch on or after the date falling 5 Business Days prior to the Drawdown Date that the Refund
Guarantor still maintains the required Minimum Credit Rating; 
  

	(w)	Ownership 

 evidence
satisfactory in all respects to the Agent that the Sponsors are, directly or indirectly the legal and beneficial owner of all of the issued share capital of the Borrower, (whether ordinary, preferential or other class of share capital (including,
without limitation, subordinated debt)) other than as permitted pursuant to clause 9.2.17; 
  

	(x)	Fees and commissions 

evidence of payment or evidence that payment will be made from the first Drawing of any fees and commissions due and payable from the
Borrower to the Agent, the Security Trustee, Calyon or the Account Banks pursuant to clause 7 or any other provision of the Security Documents; 
  

	(y)	KEIC Buyer Credit Policy 

in respect of the first Drawing the prior receipt by the Agent of an original counterpart of the relevant KEIC Buyer Credit Policy, duly
executed by KEIC (together with a copy of the signing authority of the relevant officer of KEIC) and certified copy of the KEIC Acceptance Letter, such KEIC Buyer Credit Policy to be in full force and effect; 

 

	(z)	Project Co-ordination Agreement 

 evidence that the Project Co-ordination Agreement has been executed in a form and substance acceptable in all respects to the Agent acting on the instructions of all Lenders; 

 

	(aa)	KYC documentation 

receipt by each Lender of “know-your-client” documentation satisfactory to it; and 

 

	(bb)	Accounts 

 the certified
true and complete copies of the most recent audited annual financial statements of each Sponsor and the unaudited semi-annual accounts of the Borrower for the period ending on 31 December 2007. 

  
 98 

 Part 2 
 Contract Instalment Advances 

	(a)	Invoice 

 a certified
copy of the invoice in respect of which payment is due to the Builder from the Borrower; 
  

	(b)	Fees and commissions 

(other than in respect of a Contract Instalment Advance which is the first Drawing) evidence of payment or evidence that payment will be
made from the Contract Instalment Advance of any fees and commissions due from the Borrower to the Agent, Calyon, the Security Trustee or the Account Bank pursuant to the terms of clause 7 or any other provision of the Security Documents;

  

	(c)	Conditions precedent 

confirmation from the Borrower or its legal advisers that the conditions precedent set out in Part 1 to Schedule 3 remain satisfied and
to the extent necessary are satisfied and confirmation from the Borrower that no further consents and approvals are required; 
  

	(d)	Minimum Borrower Shareholders’ Equity / Additional Shareholders’ Equity 

receipt of the Relevant Amount of the Minimum Borrower Shareholders’ Equity and/or Additional Shareholders’ Equity by the Agent
in accordance with clauses 2.3.7 and 2.9 and any subordination agreement required by the Agent in connection therewith; 
  

	(e)	Drawdown Notice 

 the
Drawdown Notice in respect of the relevant Contract Instalment Advance duly executed and delivered in accordance with clause 2 of this Agreement; 
  

	(f)	No claim 

 evidence
satisfactory to the Agent in the form of a declaration of warranty from the Builder that the Builder (and any other party who may have a claim pursuant to the Building Contract) has no claims against the Vessel or the Borrower; 

 

	(g)	No variations to Building Contract 

 confirmation from the Borrower that save as permitted by this Agreement there have been no amendments or variations agreed to the Building Contract that have not been agreed by the Agent (acting on the
instructions of the Majority Lenders) and that no action has been taken by either the Builder or the Borrower which might in any way render the Building Contract inoperative or unenforceable, in whole or in any part; and 

 

	(h)	No encumbrance 

confirmation from the Borrower that there is no Encumbrance (other than a Permitted Encumbrance) of any kind created or permitted by any
person on or relating to the Building Contract or in relation to the Vessel. 

  
 99 

 Part 3 
 Delivery Date Advance 
  

	(a)	Export Licence(s) 

 a
copy, certified as a true and complete copy by an officer of the Borrower of all consents, authorisations, licences and approvals required by the Borrower and the Builder (if any) in connection with the export by the Builder of the Vessel;

  

	(b)	Vessel conditions 

evidence that the Vessel: 
  

	 	(i)	Registration and Encumbrances 

 is or simultaneously with the Delivery of the Vessel shall be registered in the name of the Borrower through the Bahamas Registry under the laws and flag of the Bahamas and confirmation from the Borrower
that the Vessel and its Earnings, Insurances and Requisition Compensation (as defined in the Deed of Covenants) are free of Encumbrances (other than Permitted Encumbrances); 

 

	 	(ii)	Classification 

 has the
classification referred to in clause 9.6.3(b) free of all overdue requirements and recommendations of the Classification Society; 
  

	 	(iii)	Insurance 

 is insured in
accordance with the provisions of the Security Documents and all requirements of the Security Documents in respect of such insurance have been complied with (including without limitation, (A) confirmation from the protection and indemnity
association or other insurer with which the Vessel is, or is to be, entered for insurance or insured against protection and indemnity risks (including oil pollution risks) that any necessary declarations required by the association or insurer for
the removal of any oil pollution exclusion have been made and that any such exclusion does not apply to the Vessel and (B) receipt by the Agent of pro-forma letters of undertaking from the Approved Brokers (as defined in the relevant
Deed of Covenant)approved brokers in such form as the Agent may reasonably require); and 
  

	 	(iv)	Delivery under Time Charter 

 has been or on the Delivery Date will be delivered to, and accepted by, the Time Charterer for service under the Time Charter; 

 

	(c)	Deletion 

 evidence that
any prior registration of the Vessel in the name of the Builder has been cancelled (or confirmation from the Builder that there was no such prior registration) and that no Encumbrances other than Permitted Encumbrances are registered against the
Vessel on such register; 
  

	(d)	Security and delivery documents 

 certified true copies of the Management Agreement, the Builder’s Certificate and the Protocol of Delivery and Acceptance and originals of the Mortgage, the Deed of Covenants, the Assignment
and, the Manager’s Undertaking and the Management Agreement Consent and Acknowledgement each duly executed; 

 

  
 100

	(e)	Borrower’s further corporate authorisations 

 copies of the resolutions of the Borrower’s directors and (if necessary) shareholders evidencing authorisation of the acceptance of the delivery of the Vessel and authorisation and approval of the
Mortgage, the Deed of Covenants and the transactions contemplated therein and any other documents issued or to be issued pursuant thereto and authorising its appropriate officer or other representative to execute the same on its behalf certified in
the manner referred to in paragraph (b) of Part 1 of this Schedule (or other evidence of such authorisation, approval and/or ratification) and any power of attorney issued pursuant to the said resolutions (such resolutions and power of attorney
to be notarised (and, to the extent required by applicable Law, apostiled) and in a form and substance acceptable in all respects to the Agent); 
  

	(f)	Mortgage registration 

evidence that the Mortgage has been registered against the Vessel through the Bahamas Registry under the laws and flag of the Bahamas;

  

	(g)	Notices of assignment and acknowledgements 

 originals of duly executed notices of assignment required by the terms of the Deed of Covenants and the Assignment together with original duly executed acknowledgements thereof required by the terms of
such Security Documents and in the form(s) prescribed by such Security Documents and, in the case of the Assignment; 
  

	(h)	Insurance opinion 

 an
opinion from Bankserve, or such other insurance consultants as the Agent may instruct, on the insurances effected or to be effected in respect of the Vessel upon and following the Delivery Date in form and substance satisfactory to the Lenders;

  

	(i)	Bahamas opinion 

 an
opinion of the Agent’s special legal advisers in the Bahamas to the Agent in form and substance satisfactory to the Lenders; 
  

	(j)	Korean opinion 

 an
opinion of Kim & Chang special legal advisers in Korea to the KEIC Agent and the Agent in form and substance satisfactory to the Lenders; 
  

	(k)	Further opinions 

 any
such further opinion as may reasonably be required by the Agent to evidence the legality, validity and/or enforceability of the obligations of the Borrower and/or any Security Party under this Agreement, each of the other Security Documents and each
of the Project Documents to which it is a party; 
  

	(I)	Process agent 

 a copy,
certified as a true copy by the Borrower’s solicitors or other person acceptable to the Agent of a letter from the Borrower’s agent for receipt of service of proceedings referred to in clause 17.2 accepting its appointment under the said
clause and under each of the Mortgage, the Deed of Covenants, the Assignment and also in respect of the relevant Manager’s Undertaking in which it is or is to be appointed as agent; 

 

	(m)	Fees and commission 

evidence that the fees and commissions due under clause 7 have been paid in full (or upon drawdown of the Delivery Date Advance will have
been paid); 
  

  
 101

	(n)	Payment of Contract Price 

evidence from the Builder that the Contract Price has been (or upon drawdown of the relevant Delivery Date Advance will have been) paid in
full and a certified copy of the invoice in respect of the payment due to the Builder from the Borrower on the Delivery Date; 
  

	(o)	Drawdown Notice 

 the
Drawdown Notice in respect of the relevant Delivery Date Advance duly executed and delivered to the Agent in accordance with clause 2 of this Agreement; 
  

	(p)	Protocol of Delivery and Acceptance 

 copies, certified as true copies by a director or officer of the Borrower, of the Protocol of Delivery and Acceptance and any other documents issued by the Builder in connection with the construction and
delivery of the Vessel as the Builder shall be obliged to provide pursuant to the Building Contract; 
  

	(q)	ISM compliance 

 evidence
that the Operator has applied to the relevant Regulatory Agency for a DOC for itself and an SMC for the Vessel to be issued pursuant to the Code within any time limit required or recommended by such Regulatory Agency; 

 

	(r)	Minimum Borrower Shareholders’ Equity / Additional Shareholders’ Equity 

receipt of the Relevant Amount of the Minimum Borrower Shareholders’ Equity and/or Additional Shareholders’ Equity by the Agent
in accordance with sub-clauses 2.3.7 and 2.9 and any subordination agreement required by the Agent in connection therewith; and 
  

	(s)	Conditions precedent 

confirmation from the Borrower or their legal advisers that the conditions precedent set out in Parts 1 and 2 of Schedule 3 remain
satisfied and to the extent necessary are satisfied and confirmation from the Borrower that no further consents and approvals are required. 
  

  
 102

 Schedule 4 
 Form of Transfer Certificate 
 To: BNP Paribas S.A. as agent (the “Agent”)

 TRANSFER CERTIFICATE 
 This transfer certificate relates to a facility agreement (as the same may be from time to time amended, varied, novated or supplemented, the “Loan Agreement”) dated 2008 whereby a credit
facility of up to $210,000,000 was made available to Mint LNG III, Ltd (the “Borrower”) by a group of banks on whose behalf the Agent acts as agent and security trustee. 

 

	1	Terms defined in the Loan Agreement shall, subject to any contrary indication, have the same meanings herein. The terms “Lender” and “Transferee”
are defined in the schedule to this transfer certificate. 

  

	2	The Lender (i) confirms that the details in the Schedule hereto next to the heading “Commitment” accurately summarises its Commitment in the Loan
Agreement and (ii) requests the Transferee to accept and procure the transfer to the Transferee of the portion of such Commitment specified in the Schedule hereto next to the heading “Portion Transferred” by counter-signing and
delivering the Transfer Certificate to the Agent at its address for the service of communications specified in the Loan Agreement. 

  

	3	The Transferee requests the Agent to accept this Transfer Certificate as being delivered to the Agent pursuant to and for the purposes of clause 12.4 of the Loan
Agreement so as to take effect in accordance with the terms thereof on the Transfer Date or on such later date as may be determined in accordance with the terms thereof. 

 

	4	The Transferee confirms that it has received a copy of the Loan Agreement together with such other information as it has required in connection with this transaction
and that it has not relied and will not in the future rely on the Lender or any other party to the Loan Agreement to check or enquire on its behalf into the legality, validity, effectiveness, adequacy, accuracy or completeness of any such
information and further agrees that it has not relied and will not rely on the Lender or any other party to the Loan Agreement to access or keep under review on its behalf the financial condition, creditworthiness, condition, affairs, status or
nature of the Borrower or any other party to the Loan Agreement. 

  

	5	Execution of this Transfer Certificate by the Transferee constitutes its representation to the Transferor and all other parties to the Loan Agreement that it has power
to become a party to the Loan Agreement as a Lender on the terms herein and therein set out and has taken all steps to authorise execution and delivery of this Transfer Certificate. 

 

	6	The Transferee undertakes with the Lender and each of the other parties to the Loan Agreement that it will perform in accordance with their terms all those obligations
which by the terms of the Loan Agreement will be assumed by it after delivery of this Transfer Certificate to the Agent and satisfaction of the conditions (if any) subject to which the Transfer Certificate is expressed to take effect.

  

	7	The Lender makes no representation or warranty and assumes no responsibility with respect to the legality, validity, effectiveness, adequacy or enforceability of the
Loan Agreement or any document relating thereto and assumes no responsibility for the financial condition of the Borrower or for the performance and observance by the Borrower of any of its obligations under the Loan Agreement or any document
relating thereto and any and all such conditions and warranties, whether express or implied by law or otherwise, are hereby excluded. 

  
 103

	8	The Lender gives notice that nothing in this transfer certificate or in the Loan Agreement (or any document relating thereto) shall oblige the Lender to (i) accept
a re-transfer from the Transferee of the whole or any part of its rights, benefits and/or obligations under the Loan Agreement transferred pursuant hereto or (ii) support any losses directly or indirectly sustained or incurred by the Transferee
for any reason whatsoever including, without limitation, the non-performance by the Borrower or any other party to the Loan Agreement (or any document relating thereto) of its obligations under any such document. The Transferee acknowledges the
absence of any such obligation as is referred to in (i) or (ii) above. 

  

	9	The Security Trustee’s rights under the Security Documents remain in full force and effect and are not affected by this transfer. 

 

	10	This Transfer Certificate and the rights and obligations of the parties hereunder shall be governed by and interpreted in accordance with English law.

 THE SCHEDULE 
  

	1	Lender: 

  

	2	Transferee: 

  

	3	Transfer Date: 

  

	4	Commitment: 

  

	5	Portion Transferred: 

  

	6	Transferee’s Administration Details: 

  

			
	 [Transferor Bank]
	  	[Transferee Bank]
		
	 By:
	  	By:
		
	 Date:
	  	Date:

 BNP Paribas S.A. 
 As agent for and on behalf of itself, 
 the Borrower and the other Lender Finance Parties in the
presence of:- 
  

			
	By:	 	 
	
	Date:
[                                         
                    ]

  
 104

 Schedule 5 
 Form of Drawdown Notice 
  

	To:	BNP Paribas S.A. 

 Attention:
[•] 
 Fax : [•] 
 Copy to: [•] 
 Fax: [•] 

Date [•] 

Loan facility of up to United States Dollars $210,000,000 in respect of 

Hull No 1812 (the “Vessel”) 
 Loan Agreement dated                     2008 

We refer to the above Loan Agreement and hereby give you notice that we wish to drawdown the following Drawing: 

[a Contract Instalment Advance amounting to $[•];] 
 [a Delivery Date Advance amounting to $[•];] 
 [an Ancillary Cost Advance [in respect of the
KEIC Insurance Premium for the Vessel] amounting to $[•];] 
 Interest Period from [•] to [•]; 

on [•] 20[•] the funds should be credited to [name and number of account] with [details of bank [in New York City]]. 

[The Vessel is scheduled to be delivered on [•].] 
 We confirm that: 
  

	(i)	no event or circumstance has occurred and is continuing unremedied or unwaived which constitutes a Potential Event of Default; 

 

	(ii)	the representations and warranties contained in clauses [4] of the Loan Agreement are true and correct at the date hereof as if made with respect to the facts and
circumstances existing at the date hereof; 

  

	(iii)	the borrowing of the Loan will be within our corporate powers, has been validly authorised by appropriate corporate action and will not cause any limit on our
borrowings (whether imposed by statute, regulation, agreement or otherwise) to be exceeded; [and] 

  

	(iv)	there has been no material adverse change in our financial position from that set forth in the latest financial statements delivered to you under clause 9.1.5 of the
Loan Agreement. [;and] 

  

	(v)	[this Ancillary Cost Advance will not, when aggregated with all Ancillary Cost Advances previously advanced to us, equal a sum in excess of $36,000,000.]

 Words and expressions defined in the Loan Agreement shall have the same meanings when used herein. 

  
 105

			
	 For and on behalf of 
 MiNT LNG III, LTD

		
	By	 	 
	 Name:

Title:

  
 106

 Schedule 6 
 Calculation of the Mandatory Cost 
  

	1	The Mandatory Cost is an addition to the interest rate to compensate the Lenders for the cost of compliance with (a) the requirements of the Bank of England and/or
the Financial Services Authority (or, in either case, any other authority which replaces all or any of its functions) or (b) the requirements of the European Central Bank. 

 

	2	On the first day of each Interest Period (or as soon as possible thereafter) the Agent shall calculate, as a percentage rate, a rate (the “Additional Cost
Rate”) for each Lender, in accordance with the paragraphs set out below. The Mandatory Cost will be calculated by the Agent as a weighted average of the Lenders’ Additional Cost Rates (weighted in proportion to the percentage
participation of each Lender in the Loan) and will be expressed as a percentage rate per annum. 

  

	3	The Additional Cost Rate for any Lender lending from a Loan Office in a Participating Member State will be the percentage notified by that Lender to the Agent. This
percentage will be certified by that Lender in its notice to the Agent to be its reasonable determination of the cost (expressed as a percentage of that Lender’s participation in all loans made from that Loan Office) of complying with the
minimum reserve requirements of the European Central Bank in respect of loans made from that Loan Office. 

  

	4	The Additional Cost Rate for any Lender lending from a Loan Office in the United Kingdom will be calculated by the Agent as follows: 

 

			
	 E x 0.01
	  	
	300	  	per cent. per annum.
		  	

 Where E is the rate of charge payable by a Lender to the Financial Services Authority under the Fees
Rules in respect of the relevant financial year of the Financial Services Authority (calculated for this purpose by the Agent as being the average of the Fee Tariffs applicable to that Lender for that financial year). The resulting figure shall be
rounded to four (4) decimal places. 
  

	5	For the purposes of this Schedule: 

  

	 	(a)	“Eligible Liabilities and “Special Deposits” have the meanings given to them from time to time under or pursuant to the Bank of England Act
1998 or (as may be appropriate) by the Bank of England; 

  

	 	(b)	“Loan Office” means the office notified by a Lender to the Agent in writing on or before the date it becomes a Lender as the office through which it
will perform its obligations under the Agreement; 

  

	 	(c)	“Fee Rules” means the rules on periodic fees contained in the FSA Supervision Manual or such other law or regulation as may be in force from time to
time in respect of the payment of fees for the acceptance of deposits; 

  

	 	(d)	“Fee Tariffs” means the fee tariffs specified in the Fees Rules under the activity group A.1 Deposit acceptors (ignoring any minimum fee or zero rated
fee required pursuant to the Fee Rules but taking into account any applicable discount rate); and 

  

	 	(e)	“Participating Member State” means any member state of the European Communities that adopts or has adopted the euro as its lawful currency in
accordance with legislation of the European Union relating to European Monetary Union; 

  

	 	(f)	“Parties” means any party to the Agreement, including its successors in title permitted assigns and permitted transferees; and

  

	 	(g)	“Tariff Base” has the meaning given to it in, and will be calculated in accordance with, the Fees Rules. 

  
 107

	6	If requested by the Agent, each Lender shall, as soon as practicable after publication by the Financial Services Authority, supply to the Agent, the rate of charge
payable by that Lender to the Financial Services Authority pursuant to the Fees Rules in respect of the relevant financial year of the Financial Services Authority (calculated for this purpose by that Lender as being the average of the Fee Tariffs
applicable to that Lender for that financial year). 

  

	7	Each Lender shall supply any information required by the Agent for the purpose of calculating its Additional Cost Rate. In particular, but without limitation, each
Lender Shall supply the following information on or prior to the date on which it becomes a Lender: 

  

	 	(a)	the jurisdiction of its Loan Office; and 

  

	 	(b)	any other information that the Agent may reasonably require for such purpose. 

 

	 	Each	Lender shall promptly notify the Agent of any change to the information provided by it pursuant to this paragraph. 

 

	8	The percentages of each Lender for the purpose of E above shall be determined by the Agent based upon the information supplied to it pursuant to paragraphs 6 and 7
above and on the assumption that, unless the Lender notifies the Agent to the contrary, each Lender’s obligations in relation to cash ratio deposits and Special Deposits are the same as those of a typical bank from its jurisdiction of
incorporation with a Loan Office in the same jurisdiction as in its Loan Office. 

  

	9	The Agent shall have no liability to any person if such determination results in an Additional Cost Rate which over or under compensates any Lender and shall be
entitled to assume that the information provided by any Lender pursuant to paragraphs 3, 6 and 7 above is true and correct in all respects. 

  

	10	The Agent shall distribute the additional amounts received as a result of the Mandatory Cost to the Lenders on the basis of the Additional Cost Rate for each Lender
based on the information provided by each Lender pursuant to paragraphs 3, 6 and 7 above. 

  

	11	Any determination by the Agent pursuant to this Schedule in relation to a formula, the Mandatory Cost, an Additional Cost Rate or any amount payable to a Lender shall,
in the absence of manifest error, be conclusive and binding on all Parties. 

  

	12	The Agent may from time to time, after consultation with the Borrower and the Lenders determine and notify to all Parties any amendments which are required to be made
to this Schedule in order to comply with any change in law, regulation or any requirements from time to time imposed by the Bank of England, the Financial Services Authority or the European Central Bank (or, in any case, any other authority which
replaces all or any of its functions) and any such determination shall, in the absence of manifest error, be conclusive and binding on all Parties. 

  
 108

 Schedule 7 
 Contract Instalments and Repayment Profile 

Part A 

 

							
	 Installment
	  	
Initiating Event
	  	% of Contract 
Price	 
	 First
	  	December 29, 2007	  	 	10	% 
	 Second
	  	June 18, 2009	  	 	10	% 
	 Third
	  	The later of the actual date of keel-laying and December 27, 2010	  	 	10	% 
	 Fourth
	  	The later of the actual date of launching and February 26, 2011	  	 	10	% 
	 Final
	  	At Delivery and upon execution of the Acceptance	  	 	60	% 

  
 109

 Part B 

 

													
	Outstanding	    	Repayment Amnt	 	    	Repayment %	 
	 	Closing	  	  	92,400,000	    				    			
	 	1	  	  	0.63% 91,080,000	    	 	1,320,000	  	    	 	1.429	% 
	 	2	  	  	0.64% 89,741,000	    	 	1,339,000	  	    	 	1.449	% 
	 	3	  	  	0.65% 88,380,000	    	 	1,361,000	  	    	 	1.473	% 
	 	4	  	  	0.66% 86,999,000	    	 	1,381,000	  	    	 	1.495	% 
	 	5	  	  	0.67% 85,597,000	    	 	1,402,000	  	    	 	1.517	% 
	 	6	  	  	0.68% 84,174,000	    	 	1,423,000	  	    	 	1.540	% 
	 	7	  	  	0.69% 82,729.000	    	 	1,445,000	  	    	 	1.564	% 
	 	8	  	  	0.70% 81,262,000	    	 	1,467,000	  	    	 	1.588	% 
	 	9	  	  	0.71% 79,772,000	    	 	1,490,000	  	    	 	1.613	% 
	 	10	  	  	0.72% 78,260,000	    	 	1,512,000	  	    	 	1.613	% 
	 	11	  	  	0.73% 76,725,000	    	 	1,535,000	  	    	 	1.661	% 
	 	12	  	  	0.74% 75,166,000	    	 	1,559,000	  	    	 	1.687	% 
	 	13	  	  	0.75% 73,584,000	    	 	1,582,000	  	    	 	1.712	% 
	 	14	  	  	0.77% 71,977,000	    	 	1,607,000	  	    	 	1.739	% 
	 	15	  	  	0.78% 70,346,000	    	 	1,631,000	  	    	 	1.765	% 
	 	16	  	  	0.79% 68,690,000	    	 	1,656,000	  	    	 	1.792	% 
	 	17	  	  	0.80% 67,009,000	    	 	1,681,000	  	    	 	1.819	% 
	 	18	  	  	0.81% 65,302,000	    	 	1,707,000	  	    	 	1.847	% 
	 	19	  	  	0.83% 63,569,000	    	 	1,733,000	  	    	 	1.876	% 
	 	20	  	  	0.84% 61,809,000	    	 	1,760,000	  	    	 	1.905	% 
	 	21	  	  	0.85% 60,023,000	    	 	1,786,000	  	    	 	1.933	% 
	 	22	  	  	0.86% 58,210,000	    	 	1,813,000	  	    	 	1.962	% 
	 	23	  	  	0.88% 56,369,000	    	 	1,841,000	  	    	 	1.992	% 
	 	24	  	  	0.89% 54,500,000	    	 	1,869,000	  	    	 	2.023	% 
	 	25	  	  	0.90% 52,602,000	    	 	1,898,000	  	    	 	2.054	% 
	 	26	  	  	0.92% 50,676,000	    	 	1,926,000	  	    	 	2.084	% 
	 	27	  	  	0.93% 48,720,000	    	 	1,956,000	  	    	 	2.117	% 
	 	28	  	  	0.95% 46,734,000	    	 	1,986,000	  	    	 	2.149	% 
	 	29	  	  	0.96% 44,718,000	    	 	2,016,000	  	    	 	2,182	% 
	 	30	  	  	0.97% 42,671,000	    	 	2,047,000	  	    	 	2.215	% 
	 	31	  	  	0.99% 40,593,000	    	 	2,078,000	  	    	 	2.249	% 
	 	32	  	  	1.00% 38,483,000	    	 	2,110,000	  	    	 	2.284	% 
	 	33	  	  	1.02% 36,341,000	    	 	2,142,000	  	    	 	2.318	% 
	 	34	  	  	1.04% 34,167,000	    	 	2,174,000	  	    	 	2.353	% 
	 	35	  	  	1.05% 31,959,000	    	 	2,208,000	  	    	 	2.390	% 
	 	36	  	  	1.07% 29,718,000	    	 	2,241,000	  	    	 	2.425	% 
	 	37	  	  	1.08% 27,442,000	    	 	2,276,000	  	    	 	2.463	% 
	 	38	  	  	1.10% 25,132,000	    	 	2,310,000	  	    	 	2.500	% 
	 	39	  	  	1.12% 22,786,000	    	 	2,346,000	  	    	 	2.539	% 
	 	40	  	  	1.13% 20,405,000	    	 	2,381,000	  	    	 	2.577	% 
	 	41	  	  	1.15% 17,987,000	    	 	2,418,000	  	    	 	2.617	% 
	 	42	  	  	1.17% 15,533,000	    	 	2,454,000	  	    	 	2.656	% 
	 	43	  	  	1.19% 13,041,000	    	 	2,492,000	  	    	 	2.697	% 
	 	44	  	  	1.20% 10,511,000	    	 	2,530,000	  	    	 	2.738	% 
	 	45	  	  	1.22% 7,943,000	    	 	2,568,000	  	    	 	2.779	% 
	 	46	  	  	1.24% 5,335,000	    	 	2,608,000	  	    	 	2.823	% 
	 	47	  	  	1.26% 2,688,000	    	 	2,647,000	  	    	 	2.865	% 
	 	48	  	  	1.28%	    	 	2,688,000	  	    	 	2.909	% 
				  	44.00%	    				    			
				  		    				    	 	100.000	% 

  
 110

 Schedule 8 
 Form of Compliance Certificate 
 To: BNP Paribas S.A. (the “Agent”) 

 From: [•] (the “[•]”) 
 Date: [•] 
 Dear Sirs, 
 We refer to an agreement (the “Agreement”) dated
                         and made between (1) the banks and financial institutions listed in Schedule 1 of the Agreement as
lenders and swap providers, (2) yourselves as Agent (3) yourselves as Security Trustee and (4) yourselves as KEIC Agent (as from time to time amended, varied, novated or supplemented). 

Terms defined or construed in the Agreement have the same meanings and constructions in this Certificate. 

We attach the relevant calculation details applicable to the last four (4) financial quarters ending [•] (the “Relevant Period”)
which confirm that:- 
  

	1	The average DSCR in respect of the immediately preceding four (4) financial quarters [was/was not] equal to or greater than1:10x. Therefore the condition contained
in clause 9.1.219.1.19 of the Agreement [has/has not] been complied with in respect of the Relevant Period. 

 

	2	The average DSCR in respect of the immediately preceding two (2) financial quarters [was at all times equal to or greater than/fell below] 1.06x. Therefore the
condition contained in clause 9.1.219.1.19 of the Agreement [has/has not] been complied with. 

 

	3	The Leverage Ratio for the immediately preceding four (4) financial quarters did not exceed 4:1. Therefore, the contained in clause
9.1.219.1.19 of the Agreement [has/has not] been complied with 

  

			
		
	Signed:	 	 
		 	 Duly authorised representative of 
 MiNT LNG Ill, LTD

  
 111

 Exhibit A 
 MiNT LNG I 
 Long-Form Confirmation
LettersLetter between the Borrower and BNP Paribas S.A. dated 20 August 2008 and 28 August 2008 

MiNT LNG III Long-Form Confirmation Letters between the Borrower and BNP Paribas S.A. dated 20 August 2008 and 28 August 2008

 MiNT LNG III Long Form Confirmation Letters between the Borrower and BNP Paribas S.A. dated 22 August 2008 and 29 August
20082 October 2008 as amended on 9 October 2008 

MiNT LNG IV Long Form Confirmation Letters between the Borrower and BNP Paribas S.A. dated 22 August 2008 and 29 August 2008

  
 112

 IN WITNESS of which the parties to this Agreement have executed this Agreement the day and year first
before written. 
  

			
	 SIGNED by
	  	)
	duly authorised for and on behalf	  	)
	of MiNT LNG III, LTD.	  	)
		
	SIGNED by	  	)
	duly authorised for and on behalf	  	)
	of BNP PARIBAS S.A. (as a Lender and a Swap Provider)	  	)
		
	SIGNED by	  	)
	duly authorised for and on behalf	  	)
	of CALYON (as a Lender and a Swap Provider)	  	)
		
	SIGNED by	  	)
	duly authorised for and on behalf	  	)
	of DNB NOR BANK ASA (as a Lender and a Swap Provider)	  	)
		
	SIGNED by	  	)
	duly authorised for and on behalf	  	)
	of SOCIETE GENERALE	  	)
	(as a Lender and a Swap Provider)	  	)
		
	SIGNED by	  	)
	duly authorised for and on behalf	  	)
	of THE BANK OF TOKYO-MITSUBISHI UFJ, LTD.	  	)
	(as a Lender and a Swap Provider)	  	)
		
	SIGNED by	  	)
	duly authorised for and on behalf	  	)
	of SUMITOMO MITSUI BANKING CORPORATION	  	)
	BRUSSELS BRANCH	  	)
	(as a Lender)	  	)
		
	SIGNED by	  	)
	duly authorised for and on behalf	  	)
	of SMBC CAPITAL MARKETS, INC.	  	)
	(as a Swap Provider)	  	)
		
	SIGNED by	  	)
	duly authorised for and on behalf	  	)
	of BNP PARIBAS S.A.	  	)
	(as Agent)	  	)

  
 113

			
		
	 SIGNED by
	  	)
	 duly authorised for and on behalf
	  	)
	 of BNP PARIBAS S.A.
	  	)
	 (as the Security Trustee)
	  	)
		
	 SIGNED by
	  	)
	 duly authorised for and on behalf
	  	)
	 of BNP PARIBAS S.A.
	  	)
	 (as the KEIC Agent)
	  	)

  
 114Exhibit 4.22

 Exhibit 4.22 
 EXECUTION VERSION 
 Dated 10 October 2008 

 
  

 

							
	 MiNT LNG IV, LTD.
 (as Borrower)
  
	  		  	 	(1	) 
	 The Banks and Financial Institutions listed
 in Annex 1
 (as Lenders)

 
	  		  	 	(2	) 
	 The Banks and Financial Institutions listed
 in Annex 1
 (as Swap Providers)

 
	  		  	 	(3	) 
	 BNP PARIBAS S.A.
 (as Agent)
  
	  		  	 	(4	) 
	 BNP PARIBAS S.A.
 (as Security Trustee)
  
	  		  	 	(5	) 
	 and

 
	  		  			
	 BNP PARIBAS S.A.
 (as KEIC Agent)
	  		  	 	(6	) 

  
  

DEED OF AMENDMENT AND 
 RESTATEMENT 
 relating to a Loan Agreement of 

US$92,400,000 Buyer Credit and 
 $117,600,000 Commercial Loan for one 
 160,000 cbm LNG carrier Hull
No. 1813 at 
 Samsung Heavy Industries Co., Ltd. 

 
  

 

 CONTENTS 

 

					
	Clause	  	Page	 
		
	 1       Definitions
	  	 	1	  
		
	 2       Amendments to the Loan Agreement
	  	 	1	  
		
	 3       Miscellaneous
	  	 	2	  
		
	 Annex 1
	  	 	6	  

 THIS DEED is made on 10 October 2008 BETWEEN: 

 

	(1)	MiNT LNG IV, LTD., being a company organised and existing under the laws of the Bahamas whose registered office is at 50 Shirley Street, P.O. Box CB—13937,
Nassau, The Bahamas (the “Borrower”); and 

  

	(2)	the banks and financial institutions listed in Schedule 1 Part 1 in Annex 1, each acting through its office at the address indicated against its name in Schedule 1 Part
1 in Annex 1 (together the “Lenders” and each a “Lender”); and 

  

	(3)	the banks and financial institutions listed in Schedule 1 Part 2 in Annex 1, each acting through its office at the address indicated against its name in Schedule 1 Part
2 in Annex 1 (together the “Swap Providers” and each a “Swap Provider”); and 

  

	(4)	BNP PARIBAS S.A., acting as agent with its registered office at 16 boulevard des Italiens 75009 Paris and registration number 662 042 449 RSC Paris for the
Lenders and the Swap Providers (in that capacity the “Agent”); and 

  

	(5)	BNP PARIBAS S.A., acting as security trustee through its office at 16 boulevard des Italiens 75009 Paris and registration number 662 042 449 RSC Paris for the
Lenders and the Swap Providers (in that capacity the “Security Trustee”); and 

  

	(6)	BNP PARIBAS S.A., acting as agent through its office at 24/F, Taepyeongno Building 310, Taepyeongno 2-ga, Jung-gu, Seoul 100-767, for the Lenders under the KEIC
Buyer Credit Policy (as this term is defined in Annex 1) (in that capacity the “KEIC Agent”). 

 WHEREAS:

  

	(A)	By a loan agreement (the “Loan Agreement”) dated 11 September 2008 and made between the Borrower, the Lenders, the Agent, the KEIC Agent, the
Security Trustee and the Swap Providers, pursuant to which the Lenders agreed (inter alia) to loan to the Borrower, upon the terms and conditions therein contained, a buyer credit tranche of up to the lesser of (i) forty-four per cent.
(44%) of eighty per cent. (80%) of the Total Project Cost (as defined in Annex 1) and (ii) ninety two million four hundred thousand Dollars ($92,400,000) and a commercial tranche of up to the lesser of (i) fifty-six per cent.
(56%) of eighty per cent. (80%) of the Total Project Cost (as defined in Annex 1) and (ii) one hundred and seventeen million six hundred thousand Dollars ($117,600,000) to assist in financing the 160,000 cbm LNG carrier with hull
number 1813 at Samsung Heavy Industries Co., Ltd. 

  

	(B)	The parties to this Deed wish to amend and restate the Loan Agreement, as set out herein, to take effect from the date of this Deed. 

NOW IT IS HEREBY AGREED as follows: 
  

	1	Definitions 

  

	1.1	In this Deed: 

“Dollars” and “$” means the lawful currency of the United States of America from time to time; and

 “Restated Loan Agreement” means the agreement as set out in Annex 1. 

 

	2	Amendments to the Loan Agreement 

  

	2.1	The parties to this Deed hereby confirm that with effect from the date of this Deed, but without prejudice to any accrued rights and obligations, the Loan Agreement
shall be amended and restated in its entirety by and shall be construed in accordance with the Restated Loan Agreement and the parties to this Deed agree that they are and shall be bound by all of the provisions of the Restated Loan Agreement.

  
 1 

	3	Miscellaneous 

  

	3.1	Clauses 14 and 17 of the Loan Agreement shall, mutatis mutandis, be incorporated in this Deed as if set out herein. 

 

	3.2	This Deed may be executed in any number of counterparts, to the effect that any single counterpart or set of counterparts taken together executed and delivered by all
of the parties shall constitute one and the same instrument. 

 IN WITNESS whereof this Deed is executed by the parties on
the day and year first above written. 

  
 2 

			
	 EXECUTED AS A DEED

by and on behalf of 
 MiNT LNG
IV, LTD.
 (as Borrower)
 by YUJI
ISHIMARU
 in the presence of:

ChuPete
 Christian Petersen

1-12-32 Akasaka Tokyo Japan

Attorney
	  	 )
 )

) /s/ YUJI
ISHIMARU                                

)
 )

 EXECUTION PAGE—AMENDMENT AND RESTATEMENT AGREEMENT 

 

					
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 MiNT LNG IV, LTD.
	  	)	  	
	 (as Borrower)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	
			
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 BNP PARIBAS S.A.
	  	)	  	 /s/ Patricia LORMEAU

	 (as a Lender and a Swap Provider)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	
			
	 /s/ A. RENAUDIN DURAND-RUEL
	  		  	
	 A. RENAUDIN DURAND-RUEL
	  		  	
			
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 CALYON
	  	)	  	
	 (as a Lender and a Swap Provider)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	
			
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 DNB NOR BANK ASA
	  	)	  	
	 (as a Lender and a Swap Provider)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	

  
 3 

 EXECUTION PAGE—AMENDMENT AND RESTATEMENT AGREEMENT 

 

					
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 MINT LNG IV, LTD.
	  	)	  	
	 (as Borrower)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	
			
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 BNP PARIBAS S.A.
	  	)	  	
	 (as a Lender and a Swap Provider)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	
			
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 CALYON
	  	)	  	 /s/ [ILLEGIBLE]

	 (as a Lender and a Swap Provider)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	
			
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 DNB NOR BANK ASA
	  	)	  	
	 (as a Lender and a Swap Provider)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	

 EXECUTION PAGE—AMENDMENT AND RESTATEMENT AGREEMENT 

 

					
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 MINT LNG IV, LTD.
	  	)	  	
	 (as Borrower)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	
			
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 BNP PARIBAS S.A.
	  	)	  	
	 (as a Lender and a Swap Provider)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	
			
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 CALYON
	  	)	  	
	 (as a Lender and a Swap Provider)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	
			
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 DNB NOR BANK ASA
	  	)	  	
	 (as a Lender and a Swap Provider)
	  	)	  	 /s/ [ILLEGIBLE]

	 by
	  	)	  	[ILLEGIBLE]
	 in the presence of:
	  		  	
	 /s/ Eliza Mason
	  		  	
	Eliza Mason	  		  	

  
 3 

					
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 SOCIETE GENERALE
	  	)	  	 /s/ [ILLEGIBLE]

	 (as a Lender and a Swap Provider)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:   ELSA GAMBARDELLA
	  		  	
	   SG HOUSE, 41 TOWER HILL
	  		  	
	   LONDON EC3N 4SG
	  		  	
			
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 THE BANK OF TOKYO-MITSUBISHI UFJ, LTD.
	  	)	  	
	 (as a Lender and a Swap Provider)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	
			
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 SUMITOMO MITSUI BANKING CORPORATION
	  	)	  	
	 BRUSSELS BRANCH
	  	)	  	
	 (as a Lender)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	
			
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 SMBC CAPITAL MARKETS, INC.
	  	)	  	
	 (as a Swap Provider)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	

					
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 SOCIETE GENERALE
	  	)	  	
	 (as a Lender and a Swap Provider)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	
			
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 THE BANK OF TOKYO-MITSUBISHI UFJ, LTD.
	  	)	  	 /s/ [ILLEGIBLE]

	 (as a Lender and a Swap Provider)
	  	)	  	
	 by
	  	)	  	
	 in the presence of: MASAYUKI FUJIKI
	  		  	 /s/ [ILLEGIBLE]

			
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 SUMITOMO MITSUI BANKING CORPORATION
	  	)	  	
	 BRUSSELS BRANCH
	  	)	  	
	 (as a Lender)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	
			
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 SMBC CAPITAL MARKETS, INC.
	  	)	  	
	 (as a Swap Provider)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	

					
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 SOCIETE GENERALE
	  	)	  	
	 (as a Lender and a Swap Provider)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	
			
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 THE BANK OF TOKYO-MITSUBISHI UFJ, LTD
	  	)	  	
	 (as a Lender and a Swap Provider)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	
			
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 SUMITOMO MITSUI BANKING CORPORATION
	  	)	  	
	 BRUSSELS BRANCH
	  	)	  	
	 (as a Lender)
	  	)	  	 /s/ [ILLEGIBLE]

	 by
	  	)	  	
	 in the presence of:
	  		  	
	 /s/ ELIANA MILIOU
	  		  	
	 ELIANA MILIOU
	  		  	
	 NORTON ROSE LLP
	  		  	
			
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	
	 SMBC CAPITAL MARKETS, INC.
	  	)	  	
	 (as a Swap Provider)
	  	)	  	
	 by
	  	)	  	 /s/ [ILLEGIBLE]

	 in the presence of:
	  		  	
	 /s/ ELIANA MILIOU
	  		  	
	 ELIANA MILIOU
	  		  	
	 NORTON ROSE LLP
	  		  	

					
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	 /s/ Patricia LORMEAU

	 BNP PARIBAS S.A.
	  	)	  	
	 (as Agent)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	
			
	 /s/ A. RENAUDIN DURAND-RUEL 
	  		  	
	 A. RENAUDIN DURAND-RUEL
	  		  	
			
	 EXECUTED AS A DEED
	  	)	  	
	 by and on behalf of
	  	)	  	 /s/ Patricia LORMEAU

	 BNP PARIBAS S.A.
	  	)	  	
	 (as the Security Trustee)
	  	)	  	
	 by
	  	)	  	
	 in the presence of:
	  		  	
			
	 /s/ A. RENAUDIN DURAND-RUEL 
	  		  	
	 A. RENAUDIN DURAND-RUEL
	  		  	
			
	 EXECUTED AS A DEED
	  	)	  	 /s/ Patricia LORMEAU

	 by and on behalf of
	  	)	  	
	 BNP PARIBAS S.A.
	  	)	  	
	 (as the KEIC Agent)
	  	)	  	
	 by
	  	)	  	
	 in the presence of: 
	  		  	
			
	 /s/ A. RENAUDIN DURAND-RUEL 
	  		  	
	 A. RENAUDIN DURAND-RUEL
	  		  	

  
 5 

 Annex 1 
 RESTATED LOAN AGREEMENT 

  
 6 

 Dated 11 September 2008 

 
 (as amended
and restated by a Deed of Amendment 
 and Restatement dated 10 October 2008) 

 
  

MiNT LNG IV, LTD. 

(as Borrower) 

and 
 The Banks
and Financial Institutions listed herein as Lenders 
 (as Lenders) 

and 
 The Banks
and Financial Institutions listed herein 
 (as Swap Providers) 

and 
 BNP PARIBAS
S.A. 
 (as Agent) 
 and 
 BNP PARIBAS S.A. 

(as Security Trustee) 
 and 
 BNP PARIBAS S.A. 

(as KEIC Agent) 

US$92,400,000 BUYER CREDIT AND 
 US$117,600,000 COMMERCIAL LOAN for one 
 160,000 cbm LNG CARRIER Hull No 1813 at

 SAMSUNG HEAVY INDUSTRIES CO., LTD. 
  

 

					
	CONTENTS	  	Page	 
	 1       Definitions and Interpretation
	  	 	2	  
	 2       The Loan and its Purpose
	  	 	20	  
	 3       Conditions precedent and subsequent for the Loan
	  	 	23	  
	 4       Representations and Warranties
	  	 	25	  
	 5       Repayment and Prepayment
	  	 	30	  
	 6       Interest
	  	 	35	  
	 7       Fees
	  	 	36	  
	 8       Security, Accounts and Application of Moneys
	  	 	3738	  
	 9       Covenants
	  	 	41	  
	 10     Events of Default
	  	 	6466	  
	 11     Set-Off and Lien
	  	 	6870	  
	 12     Assignment and Transfer
	  	 	6971	  
	 13     Payments, Reserve Requirements and Illegality
	  	 	7173	  
	 14     Communications
	  	 	7577	  
	 15     General Indemnities
	  	 	7678	  
	 16     Miscellaneous
	  	 	7880	  
	 17     Law and Jurisdiction
	  	 	8486	  
	 Schedule 1 Part I: The Lenders, the Commitments and the Proportionate Shares
	  	 	8587	  
	 Schedule 2 The Vessel
	  	 	9294	  
	 Schedule 3 Documents and evidence required as conditions precedent
	  	 	9395	  
	 Schedule 4 Form of Transfer Certificate
	  	 	101103	  
	 Schedule 5 Form of Drawdown Notice

Schedule 6 Calculation of the Mandatory Cost
	  	 
 	103105
105107	  
  
	 Schedule 7 Contract Instalments and Repayment Profile
	  	 	107109	  
	 Schedule 8 Form of Compliance Certificate
	  	 	108111	  
	 Exhibit A
	  	 	109112	  

 LOAN FACILITY AGREEMENT (the “Agreement”) 

Dated:
                                         
                             2008 
 BETWEEN: 
  

	(1)	MiNT LNG IV, LTD., being a company organised and existing under the laws of the Bahamas whose registered office is at 50 Shirley Street, P.O. Box CB—13937,
Nassau, The Bahamas (the “Borrower”); and 

  

	(2)	the banks and financial institutions listed in Schedule 1 Part 1, each acting through its office at the address indicated against its name in Schedule 1 Part 1
(together the “Lenders” and each a “Lender”); and 

  

	(3)	the banks and financial institutions listed in Schedule 1 Part 2, each acting through its office at the address indicated against its name in Schedule 1 Part 2
(together the “Swap Providers” and each a “Swap Provider”); and 

  

	(4)	BNP PARIBAS S.A., acting as agent with its registered office at 16 boulevard des Italiens 75009 Paris and registration number 662 042 449 RSC Paris for the
Lenders and the Swap Providers (in that capacity the “Agent”); and 

  

	(5)	BNP PARIBAS S.A., acting as security trustee through its office at 16 boulevard des Italiens 75009 Paris and registration number 662 042 449 RSC Paris for the
Lenders and the Swap Providers (in that capacity the “Security Trustee”); and 

  

	(6)	BNP PARIBAS S.A., acting as agent through its office at 24/F, Taepyeongno Building 310, Taepyeongno 2-ga, Jung-gu, Seoul 100-767, for the Lenders under the KEIC
Buyer Credit Policy (in that capacity the “KEIC Agent”). 

 WHEREAS: 

 

	(A)	The Borrower has agreed to purchase the Vessel from the Builder on the terms of the Building Contract and will register the Vessel on delivery on Bahamas flag.

  

	(B)	Each of the Lenders has agreed to advance to the Borrower its Buyer Credit Commitment (aggregating, with all the other Buyer Credit Commitments from the Lenders, up to
an amount equal to the Buyer Credit Maximum Amount) to finance part of the Contract Price (the “Buyer Credit”, as more particularly defined in clause 1.1 below). 

 

	(C)	Each of the Lenders has agreed to advance to the Borrower its Commercial Loan Commitment (aggregating, with all the other Commercial Loan Commitments from the Lenders,
up to an amount equal to the Commercial Loan Maximum Amount) to finance part of the Contract Price and, subject to clause 2.3.3, 100% of the Ancillary Costs (the “Commercial Facility”, as more particularly defined in clause 1.1
below). 

  

	(D)	The Borrower has agreed to time charter the Vessel to Angola LNG Supply Services LLC, a limited liability company duly organised under the laws of the State of
Delaware, USA (the “Time Charterer”), pursuant to the terms of the Time Charter (as defined below). 

  

	(E)	Pursuant to (inter alia) this Agreement, and as a condition precedent to the several obligations of the Lenders to make the Buyer Credit and the Commercial Loan
available to the Borrower, the Borrower has, amongst other things agreed to execute and deliver a first priority mortgage over the Vessel as security for the payment of the Indebtedness. 

 

	(F)	The Lender Finance Parties (as defined below) have agreed to enter into an Intercreditor Deed amongst, inter alios, themselves and the Borrower to, inter alia, regulate
the priorities in respect of each of them under the Security Documents. 

  
 1 

     IT IS AGREED as follows:- 

 

	   1	Definitions and Interpretation 

  

	1.1	Definitions 

 In
this Agreement:- 
 “Account Bank” means BNP Paribas S.A., London Branch. 

“Account Bank Fee Letter” means the fee letter in respect of the fee referred to in clause 7.5 and made between the
Borrower and the Account Bank. 
 “Accounts” means all of the Revenue Account, the Dry Docking Reserve Account,
the Retention Account, the Debt Service Reserve Account, the Dividend Lock-up Account and the Distribution Account. 

“Account Charge” means the deed of charge over the Revenue Account, the Dry Docking Reserve Account, the Retention
Account, the Debt Service Reserve Account and the Dividend Lock-up Account in respect of the Vessel, as referred to in clause 8.1.4. 
 “Additional Shareholders’ Equity” has the meaning given to that term in the Letter of Sponsors Undertaking. 
 “Affiliate” means in relation to any entity, a Subsidiary of that entity, a Holding Company of that entity or any other Subsidiary of that Holding Company. 

“Agency Fee Letter” means the fee letter in respect of the fee referred to in clause 7.3 and made between the Borrower
and the Agent. 
 “Ancillary Costs” means costs accruing or incurred or repayments or reimbursements to be made
by the Borrower up to and upon the Delivery Date, or consequent upon Delivery, in respect of: 
  

	 	(a)	the supervision by the Supervisor or its employees of the construction of the Vessel by the Builder which are payable pursuant to the Supervision Agreement or any other
amount payable pursuant to the Supervision Agreement; 

  

	 	(b)	the acquisition of spare parts under the Depot Spares Sharing Agreement; 

  

	 	(c)	all interest, arrangement fees, commitment fees and agency fees in respect of the Loan falling due for payment and/or accruing on or before the Delivery Date;

  

	 	(d)	corporate management fees payable to Mitsui by the Borrower under the Corporate Management Agreement; 

 

	 	(e)	all costs and fees payable by the Borrower in connection with the arrangement of the facility evidenced by this Agreement and the negotiation and finalisation of the
Security Documents to which the Borrower is, or is to be, a party and in relation to the facility generally (including costs and expenses in connection with the registration of the Vessel); 

 

	 	(f)	all costs and expenses incurred by the Borrower in connection with modifications made to the Vessel prior to delivery of the Vessel pursuant to and in accordance with
the Building Contract and the Time Charter; 

  

	 	(g)	all costs and expenses incurred by the Borrower in connection with the Angolanization Agreement; 

 

	 	(h)	the KEIC Insurance Premium; and 

  
 2 

	 	(i)	any other costs approved by the Agent in writing (acting on the instructions of the Majority Lenders), 

but, for the avoidance of doubt, Ancillary Costs shall never cover any item, element or service to be provided by the Builder pursuant to
the Building Contract and which is included in the Contract Price. 
 “Ancillary Costs Advance” means a Drawing
for the purpose of paying Ancillary Costs incurred by the Borrower and for the purpose more particularly described in clause 2.3. 
 “Angola LNG” means Angola LNG Ltd, a company established and existing under the laws of Bermuda. 
 “Angola LNG Project” means the construction and operation of the approximately one-train liquefaction plant of 5 Mtpa of LNG production capacity constructed or (as the context may
require) to be constructed in the vicinity of Kwanda Island in the Zaire Province of Angola, the purchase by the Time Charterer of LNG from Angola LNG for transportation on the Vessel and the sale of the regasified LNG transported on the Vessel
pursuant to the Gas Sales and Purchase Agreements and the purchase of feed gas by Angola LNG from the Gas Suppliers under the Gas Supply Agreements. 
 “Angolanization Agreement” means the Angolanization Agreement dated 18 December 2007 between the Borrower and the Time Charterer. 

“Arrangement Fee Letter” means the fee letter in respect of the fee referred to in clause 7.1 and made between the
Borrower and the Agent. 
 “Assignment” means the deed of assignment of Insurances, Earnings and Requisition
Compensation in respect of the Vessel as referred to in clause 8.1.3. 
 “Authorisation” means an
authorisation, consent, approval, resolution, licence, exemption, filing, notarisation or registration. 
 “Authorised
Investments” means deposits and/or investments with the Account Bank with varying minimum amounts and periods applying for each case and subject to the prior written approval from the Account Bank. 

“Availability Period” means the period from and including the Execution Date to and including the Availability
Termination Date. 
 “Availability Termination Date” means, the earlier of (a) the date falling 290 days
after the Scheduled Delivery Date of the Vessel, (b) the date falling thirty (30) days after the Delivery Date of the Vessel, (c) the date on which the Time Charterer gives written consent to the Borrower permitting the Borrower to
cancel the Building Contract in accordance with its terms and (d) the date on which the Total Commitments are reduced to zero pursuant to any term of this Agreement, or such other date as may be agreed in writing by the Agent acting on the
instructions of all Lenders and KEIC. 
 “Borrower Priority Payments” means (a) any duly evidenced
payments made pursuant to the Insurances in respect of repairs to the Vessel paid for by the Sponsors on behalf of the Borrower (to the extent it is permitted to do so pursuant to clause 9.5) prior to the receipt of such Insurance proceeds and
(b) any duly evidenced payments received by the Borrower from the Time Charterer which reimburse the Borrower for the costs incurred by the Sponsors on behalf of the Borrower in relation to modifications to the Vessel which have been requested
by the Time Charterer pursuant to the Time Charter and which are reimbursed by the Time Charterer in a lump-sum manner and not through an adjustment to the payment of charterhire under the Time Charter. 

“Borrower Shareholders” means at any time from and including the Delivery Date means, Mitsui, NYK LNG and Teekay or in
any case, any other person who has become a Borrower Shareholder in place of any of them as permitted by and pursuant to clause 9.2.17 and “Borrower Shareholder” means any one of them. 

  
 3 

 “Break Costs” means the amount (if any) by which: 

 

	 	(a)	the interest which a Lender Finance Party should have received for the period from the date of receipt of all or any part of its participation in the Loan or any Unpaid
Sum to the last day of the current Interest Period in respect of that Loan or Unpaid Sum, had the principal amount or Unpaid Sum received been paid on the last day of that Interest Period; 

exceeds: 
  

	 	(b)	the amount which that Lender Finance Party would be able to obtain by placing an amount equal to the principal amount or Unpaid Sum received by it on deposit with a
leading bank in the London interbank market for a period starting on the Business Day following receipt or recovery and ending on the last day of the current Interest Period. 

and “Break Gains” means the amount (if any) by which the amount in (b) exceeds the amount in (a). 

“Builder” means Samsung Heavy Industries Co., Ltd., a company incorporated in the Republic of Korea with its registered
office at 34th FI., Samsung Insurance Seocho Tower 1321-15, Seocho-Dong, Seocho-Gu, Seoul, Korea 137-857. 
 “Building
Contract” means the contract dated 18 December 2007 on the terms and subject to the conditions of which the Builder has agreed to construct the Vessel for, and deliver the Vessel to the Borrower. 

“Building Contract Assignment Consent and Acknowledgement” means in relation to the Building Contract, the
acknowledgement of notice of and consent to, the assignment of the Building Contract to be given by the Builder in the form scheduled to the Deed of Assignment of Building Contract and Refund Guarantee. 

“Business Day” means a day (other than a Saturday or Sunday) on which banks are open for business in London, Paris,
Seoul, Tokyo and New York. 
 “Buyer Credit” means the aggregate amount of all the Buyer Credit Commitments
advanced or to be advanced by the Lenders to the Borrower under clause 2 or, where the context requires, the aggregate amounts advanced and for the time being outstanding. 
 “Buyer Credit Commitments” means the aggregate of the Commitments of the Lenders for the Vessel as shown in the column headed “Buyer Credit” in Schedule 1, Part 1 as the
same is reduced by the relevant clauses of this Agreement and which shall at no time exceed the Buyer Credit Maximum Amount. 

“Buyer Credit Margin” means zero point seven eight per cent (0.78%) per annum. 

“Buyer Credit Maximum Amount” means the lesser of (a) forty four per cent. (44%) of eighty per cent.
(80%) of the Total Project Cost and (b) ninety two million four hundred thousand Dollars ($92,400,000). 

“Calyon” means Calyon, a credit institution established under the laws of France, acting through its office at 9 quai du
Président Paul Doumer, 92920 Paris, La Défense Cédex, France. 
 “Change of Control” means
either (i) in respect of the Borrower that the Borrower Shareholders either together or any one or more of them shall cease, for any reason whatsoever, to own or control directly or indirectly, sixty-six per cent. (66%) of the shares of
the Borrower or, (ii) in respect of Teekay LNG that as from Delivery and provided that Teekay has transferred its shares in the Borrower to Teekay LNG, Teekay ceases to hold, directly or indirectly at least fifty-one per cent. (51%) of the
voting power from time to time in Teekay GP LLC, the general partner in Teekay LNG. 

  
 4 

 “Classification” means the classification referred to in and as required
by, clause 9.6.3(b). 
 “Classification Society” means the American Bureau of Shipping or such other
classification society which is a member of the International Association of Classification Societies and which the Agent shall at the Borrower’s request have agreed in writing shall be treated as the Classification Society for the Vessel for
the purpose of the Security Documents. 
 “Commercial Facility” means, the credit facility made available by
the Lenders to the Borrower pursuant to this Agreement and more particularly described in clause 2.1.2. 
 “Commercial
Loan” means the aggregate amount advanced or to be advanced by the Lenders to the Borrower under clause 2 or, where the context requires, the aggregate amounts advanced and for the time being outstanding. 

“Commercial Loan Maximum Amount” means the lesser of (a) fifty six per cent. (56%) of eighty per cent.
(80%) of the Total Project Cost and (b) one hundred and seventeen million six hundred thousand Dollars ($117,600,000). 
 “Commercial Loan Margin” means (i) during the Pre-Delivery Period one point zero zero per cent. (1.00%) per annum and (ii) during the Post-Delivery Period one point three
zero per cent. (1.30%) per annum. 
 “Commitment” means, in relation to a Lender, the amount of the Loan
which that Lender agrees under clause 2.1 to advance to the Borrower as its several liability as indicated against the name of that Lender in Schedule 1 Part I and/or Schedule 1 Part II as reduced by any relevant term of this Agreement and
“Commitments” means all or more than one of them. 
 “Commitment Fee” means the commitment fee
to be paid by the Borrower to the Agent on behalf of the Lenders pursuant to clause 7.2. 
 “Communication”
means any notice, approval, demand, request or other communication from one party to this Agreement to any other party to this Agreement. 
 “Company” means at any given time the company responsible for the Vessel’s compliance with (i) the ISM Code under paragraph 1.1.2 of the ISM Code and/or (ii) the ISPS Code
(as the case may be). 
 “Compliance Certificate” means a certificate in the form set out in Schedule 8.

 “Compulsory Acquisition” means requisition for title or other compulsory acquisition, requisition,
appropriation, expropriation, deprivation, forfeiture or confiscation for any reason of the Vessel by any Government Entity or other competent authority, whether de jure or de facto but shall exclude requisition for use or hire not involving
requisition for title. 
 “Contract Instalment Advance” means subject always to the provisions of this
Agreement, Drawings in the maximum amount not exceeding the relevant instalment amount of the Contract Price set out in each column (3) of Part A of Schedule 7 (as such sumsinstalment
amount may be adjusted as permitted under the Building Contract) which shall be applied in payment of part of the instalment of the Contract Price payable by the Borrower at the completion of the relevant stage of construction of the Vessel
pursuant to the Building Contract. 
 “Contract Price” means the actual amount payable for the Vessel pursuant
to the Building Contract. 
 “Corporate Management Agreement” means the Corporate Management and Services
Agreement executed or (as the context may require) to be executed between the Borrower and Mitsui. 

  
 5 

 “Credit Support Document” means any document described as such in the Swap
Agreements and where the context permits, any other document referred to in any Credit Support Document which has the effect of creating an Encumbrance in favour of any of the Lender Finance Parties. 

“Currency of Account” means, in relation to any payment to be made to a Lender Finance Party pursuant to any of the
Security Documents, the currency in which that payment is required to be made by the terms of the relevant Security Document. 

“Debt Service Amount” means in relation to any period all interest, principal and fees payable by the Borrower during
that period under or pursuant to this Agreement, the Swap Agreements and any transactions under the Swap Agreements less any amounts receivable by the Borrower during that period under or pursuant to the Swap Agreements. 

“Debt Service Reserve Account” means the account numbered 09618 078603 004 54 USD and designated the “Debt Service
Reserve Account” in respect of the Vessel, held in the name of the Borrower with the Account Bank and includes each sub-account thereof or time deposit account constituted by moneys originally held on the Debt Service Reserve Account and any
other account of the Borrower with the Account Bank designated by the Agent to be the Debt Service Reserve Account for the purposes of this Agreement, in each case pledged in favour of the Security Trustee. 

“Deed of Assignment of Building Contract and Refund Guarantee” means the deed of assignment referred to in clause 8.1.1.

 “Deed of Assignment of Contracts” means the deed of assignment referred to in clause 8.1.5. 

“Deed of Covenants” means the deed of covenants referred to in clause 8.1.2. 

“Default Rate” means the rate which is the aggregate of LIBOR, any Mandatory Cost, the Margin and one point zero zero
per cent. (1.00%) per annum. 
 “Delivery Date” means the date on which the Vessel is actually delivered
by the Builder to the Borrower under the Building Contract and accepted by the Time Charterer under the Time Charter. 

“Delivery Date Advance” means a Drawing made, or to be made to finance the instalment of the Contract Price falling due
on the Delivery Date. 
 “Depot Spare Parts” has the meaning given to that term in the Depot Spares Sharing
Agreement. 
 “Depot Spares Sharing Agreement” means the agreement between, amongst others, the Borrower and
the Time Charterer in respect of spare parts for, inter alia, the Vessel. 
 “Distribution Account” means the
account numbered 09618 078603 006 48 USD and designated the “Distribution Account” in respect of the Vessel, held in the name of the Borrower with the Account Bank. 
 “Dividend Lock-up Account” means the account numbered 09618 078602 005 51 USD and designated the “Dividend Lock-up Account” in respect of the Vessel, held in the name of the
Borrower with the Account Bank and includes each sub-account thereof or time deposit account constituted by moneys originally held on the Dividend Lock-up Account and any other account of the Borrower with the Account Bank designated by the Agent to
be the Dividend Lock-up Account for the purposes of this Agreement, in each case pledged in favour of the Security Trustee. 

“Dividend Restriction Event” means the occurrence of one or more of the following events: 

 

	 	(a)	the Agent has not received payment in full of the first Repayment Instalment under the Buyer Credit when due; 

  
 6 

	 	(b)	an Event of Default or a Potential Event of Default has occurred and is continuing unremedied or unwaived which has a Material Adverse Effect; 

 

	 	(c)	any charterhire under the Time Charter has not been paid when due and such charterhire together with interest thereon remains unpaid;

  

	 	(d)	the Borrower has failed to demonstrate that the average DSCR for the then immediately preceding four (4) quarters is lower than 1.13x; 

 

	 	(e)	any of the Accounts (excluding the Distribution Account) is not fully funded to the amount required at that time as required pursuant to clause 8 (provided that this
shall not apply to the Debt Service Reserve Account to the extent that the Borrower’s obligation to retain the DSRA Amount in the Debt Service Reserve Account is satisfied by means of the DSRA Letter of Credit and provided further that this
shall not apply to the Dry Docking Reserve Account to the extent that, for the then applicable period, amounts have been deposited into the Dry Docking Reserve Account in accordance with clause 8.3.2); 

 

	 	(f)	a Total Loss has occurred, unless the Borrower has complied with its prepayment obligations under clause 5.5; or 

 

	 	(g)	the credit rating of an L/C Issuer falls below the Minimum Credit Rating applicable to it as described in clause 9.1.20.9.1.20 where (i) a
demand has been made under the DSRA Letter of Credit in accordance with clause 8.5 and (ii) the L/C Issuer has failed to pay the full amount so demanded. 

“Documentation Agency Fee Letter” means the fee letter in respect of the fee referred to in clause 7.4 and made between
the Borrower and Calyon. 
 “Dollars” “US$” and “$” each means available and freely
transferable and convertible funds in lawful currency of the United States of America. 
 “Dollar Equivalent”
of an amount in a currency other than Dollars for any day means the amount of Dollars required to purchase that amount at the spot rate of exchange of the Agent for the purchase of the applicable currency with Dollars in the London foreign
exchange market at 11.00 a.m. for delivery on that day. 
 “Drawdown Date” means the date on which a Drawing is
advanced. 
 “Drawdown Notice” means a notice substantially in the form set out in the relevant part of
Schedule 5. 
 “Drawing” means each borrowing of a proportion of the Commitment by the Borrower pursuant to
clause 2 whether as a Contract Instalment Advance and/or an Ancillary Cost Advance and/or the Delivery Date Advance or (as the context may require) the principal amount of such borrowing. 

“Dry Docking Reserve Account” means the account numbered 09618 078603 002 60 USD and designated the “Dry Docking
Reserve Account” in respect of the Vessel, held in the name of the Borrower with the Account Bank and includes each sub-account thereof or time deposit account constituted by moneys originally held on the Dry Docking Reserve Account and any
other account of the Borrower with the Account Bank designated by the Agent to be the Dry Docking Reserve Account for the purposes of this Agreement, in each case pledged in favour of the Security Trustee. 

“Dry Docking Reserve Account Payments” means the sum calculated by the Borrower which should be reserved in order to
meet the costs in respect of the next scheduled dry docking of the Vessel (including, without limitation, the costs in respect of the long term maintenance and repair of the Vessel), each such calculation shall be demonstrated as being fair and
reasonable to the Agent’s satisfaction not later than the date falling, in respect of the first scheduled dry docking date, three (3) Months prior to the Scheduled Delivery Date and, in respect of each subsequent scheduled dry docking
date, not later than the date falling three (3) Months prior to the immediately preceding scheduled dry docking date of the Vessel. 

  
 7 

 “DSCR” means in relation to any period the ratio which the Revenues less
Operating Costs during that period bear to the Debt Service Amount paid or payable in relation to that period. 
 “DSRA
Amount” has the meaning given to that term in clause 9.1.18. 
 “DSRA Letter of Credit” means an
irrevocable letter of credit in a form and substance acceptable in all respects to the Agent which, if issued, shall be issued by an L/C Issuer for an original amount determined by the Agent to be equal whether alone or in aggregate to 6 Months
principal and interest repayments under this Agreement or such other amounts as referred to in clause 9.1.18 and for a period of not less than 1 year or, during the final year before the Maturity Date, such other period of less than 1 year with the
prior written consent of the Agent. 
 “Earnings” means all hires including (without limitation) all time
charter hire and bareboat charter hire, freights, pool income and other sums payable to or for the account of the Borrower in respect of the Vessel including (without limitation) all remuneration for salvage and towage services, demurrage and
detention moneys, contributions in general average, compensation in respect of any requisition for hire and damages and other payments (whether awarded by any court or arbitral tribunal or by agreement or otherwise) for breach, termination or
variation of any contract for the operation, employment or use of the Vessel. 
 “Encumbrance” means any
mortgage, charge (whether fixed or floating), pledge, lien, assignment, hypothecation, preferential right, option, title retention or trust arrangement or any other agreement or arrangement which, in any of the aforementioned instances, has the
effect of creating security. 
 “Environmental Affiliate” means an agent or employee of the Borrower or a
person in a contractual relationship with the Borrower or any sub-lessee in respect of the operation, management or maintenance of the Vessel (including without limitation, the operation of or the carriage of cargo of the Vessel). 

“Environmental Approval” means any permit, licence, ruling, variance, exemption, certificate, filing, comment,
Authorisation or other approval, required at any time under any applicable Environmental Law. 
 “Environmental
Claim” means any claim by any person which arises out of or in connection with an Environmental Incident or any alleged Environmental Incident or any breach of, or non-compliance with, or otherwise relates to any Environmental Law or
Environmental Approval. 
 “Environmental Incident” means: 

 

	 	(a)	any release, discharge or emission of Environmentally Sensitive Material from the Vessel; or 

 

	 	(b)	any incident in which Environmentally Sensitive Material is released, discharged or emitted from a vessel other than the Vessel and which involves a collision between
the Vessel and such other vessel or some other incident of navigation or operation, in either case, in connection with which the Vessel is actually and/or is reasonably likely to be arrested, attached, detained or injuncted and/or where the
Borrower, or any Environmental Affiliate or any of their respective officers, employees or other persons retained or instructed by them are finally determined to be at fault or allegedly at fault or otherwise liable to any legal or administrative
action; or 

  

	 	(c)	any other incident in which Environmentally Sensitive Material is released otherwise than from the Vessel and in connection with which the Vessel is actually or is
reasonably likely to be arrested, attached, detained or injuncted and/or where the Borrower or any Environmental Affiliate or any of their respective officers, employees or other persons retained or instructed by them are finally determined to be at
fault or allegedly at fault or otherwise liable to any legal or administrative action. 

  
 8 

 “Environmental Law” means any or all laws applicable or relating to
pollution or contamination or protection of the environment, to the generation, manufacture, processing, distribution, use or misuse, treatment, storage, disposal, carriage or holding of Environmentally Sensitive Material or to actual or threatened
emissions, releases, spillages or discharges of Environmentally Sensitive Material. 
 “Environmentally Sensitive
Material” means liquefied natural gas, oil, oil products and any other element or substance whether natural or artificial and whether consisting of gas, liquid, solid or vapour (including any chemical, gas or other hazardous or noxious
substance) which is or is capable of becoming polluting, toxic, hazardous, harmful or damaging to mankind or the environment or any living organism. 
 “Event of Default” means any of the events set out in clause 10.2. 
 “Execution Date” means the date on which this Agreement is executed by each of the parties hereto. 
 “Facility Period” means the period beginning on the Execution Date and ending on the date when the whole of the Loan Outstandings and all other amounts due and owing under this Agreement
have been repaid in full and the Borrower has ceased to be under any further actual liability to the Lender Finance Parties under or in connection with the Security Documents. 
 “Fee Letters” means the Arrangement Fee Letter, the Agency Fee Letter, the Documentation Agency Fee Letter and the Account Bank Fee Letter. 

“Financial Indebtedness” means, in relation to a person (the “debtor”), a liability of the debtor:

  

	 	(a)	for principal, interest or any other sum payable in respect of any moneys borrowed or raised by the debtor; 

 

	 	(b)	under any loan stock, bond, note or other security issued by the debtor; 

  

	 	(c)	under any acceptance credit, guarantee or letter of credit facility issued for the account of the debtor; 

 

	 	(d)	under a lease or any other agreement having the commercial effect of a borrowing or raising of money by the debtor; 

 

	 	(e)	under any foreign exchange transaction, any interest or currency swap or any other kind of derivative transaction entered into by the debtor or, if the agreement under
which any such transaction is entered into requires netting of mutual liabilities, the liability of the debtor for the net amount; or 

  

	 	(f)	under a guarantee, indemnity or similar obligation entered into by the debtor in respect of a liability of another person which would fall within paragraphs (a) to
(e) if the references to the debtor referred to the other person, 

 provided that, Financial Indebtedness
shall exclude (a) any shareholder loans and/or other debt instruments of the Borrower to the Borrower Shareholders which are fully subordinated to the Loan in accordance with clause 2.1.1 of the Letter of Sponsors Undertaking and (b) any
shareholder loans which are repaid pursuant to clause 2.3.4. 
 “Flag State” means the Bahamas. 

“GAAP” means, with respect to a person, the generally accepted accounting principles consistently applied by such person
in preparation of its financial statements. 

  
 9 

 “Gas Sales and Purchase Agreements” means the agreements entered into or
(as the context may require) to be entered into between the Time Charterer and one or more affiliates of the Gas Suppliers for the sale and purchase of the LNG transported on the Vessel to the Gulf LNG Clean Energy regasification terminal located at
the Port of Pascagoula, Mississippi. 
 “Gas Suppliers” means the suppliers of feed gas to Angola LNG pursuant
to the Gas Supply Agreements. 
 “Gas Supply Agreements” means the gas supply agreements entered into or (as
the context may require) to be entered into between each of the Gas Suppliers and Angola LNG for the supply by the Gas Suppliers of feed gas to Angola LNG for the purpose of liquefaction at the Angola LNG liquefaction plant and the subsequent sale
of LNG by Angola LNG to the Time Charterer pursuant to the LNG Sale and Purchase Agreement. 
 “Government Entity”
means and includes (whether having a distinct legal personality or not) any national or local government authority, board, commission, department, division, organ, instrumentality, court or agency. 

“Guarantee Bond” has the meaning given to that term in the Building Contract. 

“Holding Company” means, in relation to any entity (the “first entity”), any other entity in respect of
which the first entity is a Subsidiary. 
 “Indebtedness” has the meaning given to that term in the
Intercreditor Deed. 
 “Insurances” means all policies and contracts of insurance (including but not limited to
hull and machinery, all entries in protection and indemnity or war risks associations) which are from time to time taken out or entered into in respect of or in connection with the Vessel or her increased value and her Earnings and (where the
context permits) all benefits thereof, including all claims of any nature and returns of premium. 
 “Insured Loss
Value” means, at any relevant time, 110% of the aggregate from time to time of the Lender Indebtedness. 

“Intercreditor Deed” means an intercreditor deed to be entered into between (1) the Agent, (2) the Security
Trustee, (3) the Borrower, (4) the Lenders, (5) the KEIC Agent and (6) the Swap Providers. 

“Interest Payment Date” means each date for the payment of interest in accordance with clause 6. 

“Interest Period” means each interest period selected pursuant to clause 6. 

“ISM Code” means the International Safety Management Code (including the guidelines on its implementation) adopted by
the International Maritime Organisation Assembly as Resolutions A. 741(18) and A. 788(19) and incorporated into SOLAS as the same may be amended or supplemented from time to time and all further resolutions, circulars, codes, guidelines, regulations
and recommendations which are now or may in the future be issued by or on behalf of the International Maritime Organisation or any other entity with responsibility for implementing the ISM Code. 

“ISSC” means a valid international ship security certificate for a Vessel issued under the ISPS Code. 

“ISPS Code” means the International Vessel and Port Facility Security Code adopted by the International Maritime
Organisation Assembly as the same may have been or may be amended or supplemented from time to time. 
 “KEIC”
means Korea Export Insurance Corporation of 2-16 Floors, Seoul Central Building, 136 Seorin Dong, Jongro-ku, Seoul 110-729, Korea. 

  
 10 

 “KEIC Acceptance Letter” means the letter or letters to be entered into
from KEIC to, amongst others, the KEIC Agent. 
 “KEIC Buyer Credit Policy” means the Medium and Long Term
Export Insurance Policy, the General Terms and Conditions of Medium and Long Term Export Insurance (Buyer’s Credit, Standard Type) and the special policy attached thereto to be issued by KEIC in respect of 95% of the Buyer Credit in relation to
political and commercial risks. 
 “KEIC Insurance Premium” means Fourfour point
Fivefive per cent. (4.5%) of the Buyer Credit Maximum Amount. 
 “law” or
“Law” means any law, statute, treaty, convention, regulation, instrument or other subordinate legislation or other legislative or quasi-legislative rule or measure, or any order or decree of any government, judicial or public or
other body or authority, or any directive, code of practice, circular, guidance note or other direction issued by any competent authority or agency (whether or not having the force of law). 

“L/C Issuer” means a financial institution issuing the DSRA Letter of Credit and having a Minimum Credit Rating.

 “Lender Finance Parties” means the Lenders, the Agent, the Security Trustee, the KEIC Agent and the Swap
Providers. 
 “Lender Indebtedness” means the Buyer Credit Liabilities and the Commercial Liabilities (each as
defined in the Intercreditor Deed). 
 “Letter of Sponsors Undertaking” means the undertaking referred to in
clause 8.1.7 and executed or (as the context may require) to be executed by each of the Sponsors on a several basis in favour of the Security Trustee in form and substance acceptable to the Lenders. 

“Leverage Ratio” means the ratio of the Loan Outstandings to the aggregate of (without duplication) the Minimum Borrower
Shareholders’ Equity, the Additional Shareholders’ Equity (to the extent the same has been advanced) and the issued share capital of the Borrower, shareholder loans and/or other debt instruments of the Borrower to the Borrower Shareholders
and the amounts standing to the credit of its capital and revenue reserves (including any share premium account or capital redemption reserve but excluding any re-evaluation reserve). 

“LIBOR” means, in relation to a particular period: 

 

	 	(a)	the offered rate for deposits of Dollars for a period equal to such period and in an amount approximately equal to the amount in relation to which LIBOR is to be
determined at 11.00 a.m. (London time) two (2) London Business Days prior to the first day of such period as displayed on Reuters Page LIBOR 01 on the Reuters Monitor Money Rates (the “Screen Rate”) Service or such other
page as may replace such page on such system or on any other system for the time being displaying the rate so designated and if no such rate is available for any such period the rate shall be determined by interpolating between rates for such
periods as are so available; or 

  

	 	(b)	if no Screen Rate is available for Dollars for any Interest Period, LIBOR for such period shall be the arithmetic mean (rounded upwards if necessary to five decimal
places) of the rates respectively quoted to the Agent or any successor entity thereto by each of the Reference Banks (or, if not all the Reference Banks provide a quotation when requested, the arithmetic mean of the rates which are quoted) as such
Reference Banks’ offered rates for deposits of Dollars in an amount approximately equal to the amount in relation to which LIBOR is to be determined for a period equivalent to such period to prime banks in the London Interbank Market at 11.00
a.m. (London time) two (2) London Business Days prior to the first day of such period; or 

  
 11 

	 	(c)	if on such date no such rate can be ascertained pursuant to paragraph (a) or (b) of this definition, LIBOR for such period shall be the rate, determined by
the Agent at which the Agent or any successor entity thereto is able to obtain deposits of Dollars in an amount approximately equal to the amount in respect of which LIBOR is to be determined, from whatever source it may select for a period
equivalent to such period at 11.00 a.m. (London time) two (2) London Business Days prior to the first day of such period. 

 “LNG” means liquefied natural gas. 
 “LNG
Agreement” means the LNG Sales and Purchase Agreement entered or (as the context may require) to be entered into between Angola LNG and the Time Charterer pursuant to which Angola LNG will supply to the Time Charterer and the Time Charterer
will purchase from Angola LNG, LNG for transportation on the Vessel from the Angola LNG liquefaction plant to the Gulf LNG Clean Energy regasification terminal located at the Port of Pascagoula, Mississippi. 

“Loan” means the aggregate amount advanced or to be advanced by the Lenders to the Borrower under clause 2 or, where the
context requires, the aggregate amounts advanced and for the time being outstanding. 
 “Loan Outstandings” at
any time means the total of all Drawings made at that time, to the extent not reduced by repayments, prepayments and voluntary reductions. 
 “London Business Days” means a day (other than a Saturday or Sunday) on which banks are open for business in London. 

“Majority Lenders” means a Lender or Lenders whose Commitments in respect of the Loan aggregate more than sixty six
point six seven per cent (66.67%) of the aggregate of all the Commitments in respect of the Loan. 

“Manager” means NYK LNG, or another management company approved by the Agent (acting under the instructions of the
Majority Lenders and KEIC). Provided however that NYK LNG shall be entitled to subcontract its technical management function under the Management Agreement to the Sub-Manager provided that the Sub-Manager enters into a Sub-Managers Undertaking and a
Sub-Management Agreement Assignment. 
 “Management Agreement” means, in respect of the Vessel, the management
agreement, to be in form and substance acceptable to the Lenders acting reasonably, entered into, or as the case may be, to be entered into between the Borrower and the Manager providing for the Manager to manage the Vessel. 

“Management Agreement Consent and Acknowledgement” means the acknowledgement of notice and consent to be given by the
Manager in respect of the Management Agreement in the form scheduled to the Deed of Assignment of Contracts. 

“Manager’s Undertaking” means an undertaking referred to in clause 8.1.8 executed or (as the context may require)
to be executed by the Manager in favour of the Security Trustee as a condition precedent to the approval of the Management Agreement, such undertakings to be in a form and substance satisfactory to the Lenders in all respects. 

“Mandatory Cost” means for each Lender to which it applies, the cost imputed to that Lender of compliance with the
mandatory liquid asset requirements of the Bank of England and/or the banking supervision or other costs imposed by the Financial Services Authority or the European Central Bank, determined in accordance with Schedule 6 (Calculation of the
Mandatory Cost). 
 “Mandatory Prepayment Event” means any of the events set out in clauses 5.5, 5.6, 5.7,
5.8 or 5.9. 
 “Margin” means the Buyer Credit Margin or the Commercial Loan Margin as applicable. 

“Master” means the master of the Vessel from time to time. 

  
 12 

 “Material Adverse Effect” means a material adverse effect on (a) the
Borrower’s financial or operating condition or (b) the Borrower’s or any other Security Party’s ability to comply with its material obligations under any of the Security Documents or (c) the validity or enforceability of any
of the Security Documents or (d) the rights and remedies of the Lender Finance Parties under the Security Documents. 

“Maturity Date” means the date falling twelve (12) years after the Delivery Date of the Vessel. 

“Maximum Loan Amount” means two hundred and ten million Dollars ($210,000,000). 

“Minimum Credit Rating” means (a) in relation to any L/C Issuer either a minimum Standard and Poors corporate
rating of AA- or a minimum Moodys long term credit rating of Aa3 and (b) in relation to the Refund Guarantor a minimum long term credit rating of A- or equivalent by either Standard and Poors or Fitch. 

“Minimum Borrower Shareholders’ Equity” means subject always to the provisions of the Letter of Sponsors
Undertaking, a sum equal to no less than the lesser of 20% of the Scheduled Vessel Project Cost (being $52,500,000) and 20% of the Total Project Cost, made or (as the context may require) to be made available to the Borrower whether directly or
indirectly by way of contributions to the ordinary, preferential or other class of share capital of the Borrower or by way of shareholder loans and/or debt instruments of the Borrower which shareholder loans and/or debt instruments shall be
subordinated in all respects to the amounts due or owing to the Agent, the Security Trustee, the KEIC Agent, the Swap Providers or the Lenders under the Security Documents on terms acceptable to them, to be applied on a pro-rata basis with the
Drawings in respect of the costs to be funded by the Loan. 
 “Mitsui” means Mitsui & Co., Ltd. a
Japanese corporation with its registered office at 2-1, Ohtemachi 1-chome, Chiyoda-ku, Tokyo, 100-0004, Japan. 

“Moodys” means Moodys’ Investors Service of 99 Church Street, New York, NY 10007, USA and includes its successors
in title. 
 “Month” means a period starting on one day in a calendar month and ending on the numerically
corresponding day in the next calendar month, except that: 
  

	 	(a)	if the numerically corresponding day is not a Business Day, that period shall end on the next Business Day in that calendar month in which that period is to end if
there is one, or if there is not, on the immediately preceding Business Day; and 

  

	 	(b)	if there is no numerically corresponding day in the calendar month in which that period is to end, that period shall end on the last Business Day in that calendar
month. 

 The above rules will only apply to the last Month of any period, and “Monthly” shall be
construed accordingly. 
 “Mortgage” means together the first priority statutory ship mortgage together with
the Deed of Covenants collateral thereto over the Vessel made or to be made between the Borrower and the Security Trustee referred to in clause 8.1.2 (the “Mortgage”). 

“NYK” means Nippon Yusen Kabushiki Kaisha, a Japanese corporation with its registered office at 3-2, Marunouchi 2-chome,
Chiyoda-ku, Tokyo, 100-0005, Japan. 
 “NYK LNG” means NYK LNG (Atlantic) Ltd., a company incorporated in
England and Wales with its registered office at Citypoint, 1 Ropemaker Street, London EC2Y 9NY. 
 “Operating
Costs” means in relation to any period, the Borrower’s operating costs in respect of the Vessel, but excluding any unanticipated costs of a non-recurring and extraordinary nature which have not been reimbursed but which are to be
reimbursed to the Borrower (and in respect of which the Borrower shall provide such evidence as the Agent may require) and no amount in respect of which is included in the Revenues for such period. 

  
 13 

 “Operator” means any person concerned in the operation of the Vessel and
falling within the definitions of “Company” set out in the ISM Code. 
 “Permitted
Encumbrance” means: 
  

	 	(a)	Encumbrances created or contemplated by this Agreement or any of the Relevant Documents; 

 

	 	(b)	liens for unpaid crew’s wages; 

  

	 	(c)	liens for salvage; 

  

	 	(d)	liens arising by operation of law for not more than 2 Months’ prepaid hire under any charter in relation to a Vessel not prohibited by the Relevant Documents;

  

	 	(e)	liens for Master’s disbursements incurred in the ordinary course of trading; 

 

	 	(f)	other liens arising by operation of law or otherwise in the ordinary course of the operation, repair or maintenance of the Vessel and which secure amounts not exceeding
the Threshold Amount where the Borrower is contesting the claim giving rise to such lien in good faith by appropriate steps and for the payment of which adequate reserves have been made in case the Borrower finally has to pay such claim so long as
any such proceedings shall not, and may reasonably be considered unlikely to lead to the arrest, sale, forfeiture or loss of the Vessel, or any interest in the Vessel; 

 

	 	(g)	any security interest created over the Depot Spare Parts by a sister vessel in favour of its lenders; 

 

	 	(h)	any security interest created in favour of a claimant or defendant in any action of the court or tribunal before whom such action is brought as security for costs and
expenses where the Borrower is prosecuting or defending such action in good faith by appropriate steps or which are subject to a pending appeal and for which there shall have been granted a stay of execution pending such appeal and for the payment
of which adequate reserves have been made so long as any such proceedings or the continued existence of such security interest shall not and may reasonably be considered unlikely to lead to the arrest, sale, forfeiture or loss of, the Vessel or any
interest in the Vessel; and 

  

	 	(i)	security interests arising by operation of law in respect of taxes which are not overdue for payment or taxes which are overdue for payment but which are being
contested in good faith by appropriate steps and in respect of which appropriate reserves have been made so long as any such proceedings or the continued existence of such security interest shall not and may reasonably be considered unlikely to lead
to the arrest, sale, forfeiture or loss of a Vessel, or any interest in the Vessel. 

 “Post-Delivery
Period” means the period from and including the date falling immediately after the Delivery Date up to and including the last day of the Facility Period. 
 “Potential Event of Default” means any event which, with the giving of notice and/or the passage of time and/or the satisfaction of any materiality test, would
constitute an Event of Default. 
 “Pre-Delivery Period” means the period from and including the Execution Date
up to and including the Delivery Date. 
 “Project Co-ordination Agreement” means the project co-ordination
agreement entered or, as the case may be, to be entered into between the Borrower, the Time Charterer and the Security Trustee to be in form and substance satisfactory to all Lenders. 

“Project Documents” means the Building Contract, the Refund Guarantee, the Management Agreement, the Corporate
Management Agreement, the Supervision Agreement, the Tripartite Agreement, the Depot Spares Sharing Agreement, the Sub-Management Agreement and the Time Charter and any other agreements or documents which the Agent and the Borrower agree shall be a
“Project Document”. 

  
 14 

 “Proportionate Share” in respect of a Loan means, for each Lender, the
percentage that its Commitment relating to that Loan bears to the aggregate Commitments of all Lenders for that Loan from time to time, being initially the percentage indicated against the name of that Lender in Schedule 1. 

“Protocol of Delivery and Acceptance” has the meaning given to that term in the Building Contract. 

“Qualifying Entity” means a person having a long term corporate credit rating of at least BBB-with Standard and Poors or
Baa3 with Moodys; 
 “Reference Banks” means, in relation to LIBOR, the principal London offices of the Agent,
HSBC Bank plc, The Royal Bank of Scotland plc and Barclays Bank plc and such other banks as may be appointed by the Agent in consultation with the Borrower. 
 “Refund Guarantee” means the refund guarantee dated 20 December 2007 and issued by the Refund Guarantor in favour of the Borrower. 

“Refund Guarantee Consent and Acknowledgement” means the acknowledgement of notice of and consent to, the assignment in
respect of the Refund Guarantee to be given by the Refund Guarantor in the form scheduled to the Deed of Assignment of Building Contract and Refund Guarantee. 
 “Refund Guarantor” means ABN AMRO a bank established and existing under the laws of the Netherlands and acting through its offices at 6/F, Seoul Finance Centre 84, Taepyeongno 1-ga,
Jung-gu, Seoul 100-768, Korea CPO Box 3035, Seoul. 
 “Relevant Documents” means the Security Documents, the
Project Documents and the KEIC Buyer Credit Policy. 
 “Relevant Jurisdiction” means any jurisdiction in which
or where any Security Party is incorporated, resident, domiciled, has a permanent establishment, carries on, or has a place of business or is otherwise effectively connected. 
 “Repayment Date” means any date for payment of a Repayment Instalment in accordance with clause 5. 
 “Repayment Instalment” means any instalment of a Loan to be repaid by the Borrower in accordance with clause 5. 

“Requisition Compensation” means all compensation or other money which may from time to time be payable to the
Borrower as a result of the Compulsory Acquisition of the Vessel. 
 “Retention Account” means the
account numbered 09618 078603 003 57 USD and designated the “Retention Account” in respect of the Vessel, held in the name of the borrower with the Account Bank and includes each sub-account thereof or time deposit account constituted by
moneys originally held on the Retention Account and/or any other account of the Borrower, with the Account Bank designated by the Agent to be the Retention Account for the purposes of this Agreement, in each case pledged in favour of the Security
Trustee. 
 “Retention Amount” means, in relation to any Retention Date, such sum as shall be the
aggregate of: 
  

	 	(a)	 one-third
(1/
3) of the Repayment Instalment falling due for payment pursuant to clause 5.1 (as the same may have been reduced
by any permitted or required prepayment) on the next Repayment Date after the relevant Retention Date other than in the case of the final Repayment Instalment in respect of which no retention shall be made; and 

  
 15 

	 	(b)	 one-third
(1/
3) of the aggregate amount of interest falling due for payment in respect of the Loan during and at the end of
each Interest Period current at the relevant Retention Date as reduced or, as the case may be, increased by the amounts (if any) to be paid or, as the case may be, to be received by the Borrower under the Swap Agreements.

 “Retention Dates” means in relation to the Loan, the date falling one (1) Month after
the Delivery Date and each of the dates falling at Monthly intervals after such date and prior to the final Repayment Date. 

“Revenue Account” means the account numbered 09618 078603 001 63 USD and designated the “Revenue Account” in
respect of the Vessel, held in the name of the Borrower with the Account Bank and includes each sub-account thereof or time deposit account constituted by moneys originally held on the Revenue Account and/or any other account of the Borrower with
the Account Bank designated by the Agent to be the Revenue Account for the purposes of this Agreement, in each case pledged in favour of the Security Trustee. 
 “Revenues” means, in relation to any period, all moneys received or receivable by the Borrower in relation to that period including: 

 

	 	(a)	moneys received or receivable pursuant to the Time Charter; 

  

	 	(b)	amounts representing interest on the Accounts; and 

  

	 	(c)	all other amounts received or receivable by the Borrower during the relevant period, but excluding Drawings paid to the Borrower under this Agreement.

 “Revised Delivery Date” means any Revised Delivery Date as defined in Article V(d) of the
Building Contract and pursuant to which the Borrower is entitled to delay delivery of the Vessel by notice in writing to the Builder on two occasions and by up to 45 days on each occasion. 

“Scheduled Delivery Date” means 13 January 2012 or any Revised Delivery Date. 

“Scheduled Vessel Project Cost” means two hundred and sixty two million five hundred thousand Dollars
($262,500,000). 
 “Security Documents” means this Agreement, the Swap Agreement, any other Credit Support
Documents, the Deed of Assignment of Building Contract and Refund Guarantee, the Assignment, the Deed of Assignment of Contracts, the Letter of Sponsors Undertaking, the Mortgage, the Deed of Covenants, the Share
PledgesCharges, the Account Charge, the Project Co-ordination Agreement, the Building Contract Assignment Consent and Acknowledgement, the Refund Guarantee Consent and Acknowledgement, the Supervision Agreement Consent and
Acknowledgement, the Management Agreement Consent and Acknowledgement, the Sub-Management Agreement Consent and Acknowledgement, the Intercreditor Deed, the Manager’s Undertaking, the Sub-Manager’s Undertaking, the Fee Letters or (where
the context permits) any one of them and any other agreement or document which may at any time be executed to guarantee or as security for the payment or repayment of all or any part of the Indebtedness and which the Borrower and the Agent agree to
be a Security Document. 
 “Security Parties” means, at any relevant time, the Borrower, the Sponsors, the
Borrower Shareholders, the Supervisor, the Manager, the Sub-Manager and, with the consent of the Borrower, any other party who may at any time during the Facility Period be liable for, or provide security for, all or any part of the Lender
Indebtedness, and “Security Party” means any one of them. 
 “Security Trustee” means BNP
Paribas S.A. in its capacity as security trustee for the purposes of the Security Documents. 

  
 16 

 “Share PledgesCharges” means the share
pledgescharge over shares from each Borrower Shareholder in respect of the shares in the Borrower as referred to in clause 8.1.6. 
 “SOLAS” means International Convention for the Safety of Life at Sea, 1974, with Protocol 1978 and Amendments of 1981, 1983, 1988, 1991, 1992, 1994, 1996, 1998, 2000, 2002, 2003 and 2004
as the same may be further amended or supplemented, consolidated or replaced from time to time. 
 “Sponsors”
means Mitsui, NYK and Teekay, or in any case, any other person who has acceded to the Security Documents as a Sponsor in place of any of them as permitted by and pursuant to clause 9.2.17 and “Sponsor” means any one of them.

 “Standard & Poors” means Standard & Poors Rating Services of 25 Broadway, New York,
NY 10004, USA and includes its successors in title. 
 “Sub -Manager” means NYK LNG Shipmanagement (UK)
Ltd., an English company with its registered office at City Point, 1 Ropemaker Street, London, EC2Y 9NY, United Kingdom. 

“Sub Management Agreement” means the management agreement to be entered into between the Manager and the
Sub-Manager in respect of the Vessel. 
 “Sub -Manager’s Undertaking” means an undertaking
agreement as referred to in clause 8.1.9 executed or (as the context may require) to be executed by the Sub-Manager in favour of the Security Trustee as a condition precedent to the approval of the Sub-Management Agreement, such undertaking to be in
form and substance satisfactory to the Agent in all respects. 
 “Subsidiary” means a subsidiary undertaking,
as defined in section 736 Companies Act 1985 or any analogous definition under any other relevant system of law. 

“Supervision Agreement” means the supervision agreement to be entered into between the Borrower and the Supervisors as
supervisors in respect of, inter alia, the Vessel. 
 “Supervision Agreement Consent and Acknowledgement” means
the acknowledgement of notice of and consent to, the assignment in respect of the Supervision Agreement to be given by the Supervisor in the form scheduled to the Deed of Assignment of Contracts. 

“Supervisors” means Teekay Shipping Limited and NYK or any one of their respective Affiliates who are parties to the
Supervision Agreement and “Supervisors” means either of them; 
 “Swap Agreement” means
each ISDA Master Agreement and each confirmation issued thereunder between a Swap Provider and the Borrower together with any novation documentation entered into in relation to swap arrangements relating to this Agreement entered into prior to the
date hereof (together the “Swap Agreements”). 
 “Swap Margin” means the Swap Margin
applicable to each Swap Agreement as set out in the Swap Margin Side Letters. 
 “Swap Margin Side
Letters” means the letter agreement to be entered into between the Swap Providers and the Borrower setting out the Swap Margin in form and substance satisfactory to each of the Swap Providers and the Borrower. 

“Swap Providers” means each of the Lenders (including, for the avoidance of doubt, any entity which has ceased to be
a Lender pursuant to clause 12) or their respective affiliate acting in its capacity as a swap provider pursuant to a Swap Agreement and “Swap Provider” means any one or more of them. 

“Tax” includes all present and future taxes, levies (whether by deduction, withholding or otherwise), imposts, duties,
or charges of a similar nature (or any amount payable on account of or as security for any of the foregoing), including, but not limited to, income tax, corporation tax, VAT, stamp duty, customs and other impost or export duty or excise duty,
imposed by any statutory, governmental, national, international, state or local taxing or fiscal authority, body or agency or department whatsoever or any central bank, monetary agency or European Union institution, whether in the United Kingdom or
elsewhere together with interest thereon and any additions, fines, surcharges, penalties in respect thereof or relating thereto and “Taxes” and “Taxation” shall be construed accordingly. 

  
 17 

 “Teekay” means Teekay Corporation a company incorporated in the Marshall
Islands with its registered office at c/o Trust Company Complex, Ajeltake Road, Ajeltake Island, Majuro, Marshall Islands MH 96960. 
 “Teekay LNG” means Teekay LNG Partners L.P. a limited partnership formed in the Marshall Islands with its registered office at c/o Trust Company Complex, Ajeltake Road, Ajeltake
Island, Majuro, Marshall Islands MH96960. 
 “Teekay Shipping Limited” means Teekay Shipping
Limited, a Bermuda company constituted from the Commonwealth of the Bahamas with its registered office at 4th Floor, Belvedere Building, 69 Pitts Bay Road, Hamilton, HM 09, Bermuda. 

“Threshold Amount” means two million Dollars ($2,000,000) or its Dollar Equivalent. 

“Time Charter” means in respect of the Vessel, the time charter dated 18 December 2007 between the Borrower
and the Time Charterer. 
 “Time Charterer” has the meaning ascribed to that term in Recital D above.

 “Total Loss” means:- 
  

	 	(a)	an actual, constructive or compromised or arranged total loss of the Vessel; or 

 

	 	(b)	any Compulsory Acquisition of the Vessel; or 

  

	 	(c)	the hijacking, theft, condemnation, capture, seizure, arrest, detention or confiscation of the Vessel (other than where the same amounts to the Compulsory Acquisition
of the Vessel) by any person or entity, including any Government Entity, or by persons acting or purporting to act on behalf of any Government Entity, unless the Vessel is released and restored to the Borrower from such hijacking, theft,
condemnation, capture, seizure, arrest, detention or confiscation within thirty (30) days after the occurrence thereof or where such event is an insured risk under the Insurances, six (6) Months or such lesser period as is stipulated in
the relevant Insurances as being required to elapse before a Total Loss of the Vessel shall be deemed as having occurred. 

 “Total Project Cost” means a sum equal to the aggregate amount in Dollars of the Contract Price and Ancillary Costs. 

“Transfer Certificate” means a certificate materially in the form set forth in Schedule 4 or any other form agreed by
the Borrower and the Agent signed by a Lender and a Transferee whereby:- 
  

	 	(a)	such Lender procures the transfer to such Transferee of all or a part of such Lender’s rights and obligations under this Agreement upon and subject to the terms
and conditions set out in clause 12; and 

  

	 	(b)	such Transferee undertakes to perform the obligations it will assume as a result of delivery of such certificate to the Agent as is contemplated in clause 12.

 “Transfer Date” means, in relation to any Transfer Certificate, the date for the making of the
transfer specified in the schedule to such Transfer Certificate. 
 “Tripartite Agreement” means the Tripartite
Agreement dated 18 December 2007 and made between the Builder, the Borrower and the Time Charterer. 

  
 18 

 “Tripartite Agreement Consent and Acknowledgement” means the
acknowledgement of and consent to, the assignment in respect of the Tripartite Agreement to be given by the Builder and the Time Charterer in the form scheduled to the Deed of Assignment of Contracts. 

“Transferee” means a bank or other financial institution to which a Lender transfers all or part of such Lender’s
rights and obligations under this Agreement. 
 “Unpaid Sum” means any sum due and payable but unpaid by a
Security Party under the Security Documents. 
 “Value Added Tax” or “VAT” means: 

 

	 	(a)	value added tax of the United Kingdom as provided for in the VATA including legislation (delegated or otherwise) supplementary thereto, and any similar or substituted
tax, or any tax imposed, levied or assessed in the United Kingdom on added value or turnover; and 

  

	 	(b)	any similar tax imposed, levied or assessed in any jurisdiction outside the United Kingdom. 

“VATA” means the Value Added Tax Act 1994. 
 “Vessel” means the Vessel listed in Schedule 2 and everything now or in the future belonging to it on board and ashore. 

“Vessel Registry” means the Bahamas Vessel Registry. 

“Wholly-Owned Subsidiary” has the meaning given to the term “wholly-owned subsidiary” in section 736 of the
Companies Act 1985. 
  

	1.2	     Headings 

 clause headings and table of contents are inserted for convenience of reference only and shall be ignored in the interpretation of this Agreement. 

 

	1.3	     Construction of certain terms 

 In this Agreement, unless the context otherwise requires: 
  

	1.3.1	references to clauses and schedules are to be construed as references to the clauses of, and schedules to, this Agreement and references to this Agreement include its
schedules; 

  

	1.3.2	references to (or to any specified provision of) this Agreement or any other document shall be construed as references to this Agreement, that provision or that
document as in force for the time being and as amended or supplemented in accordance with the terms thereof, or, as the case may be, with the agreement of the relevant parties; 

 

	1.3.3	references to a “regulation” include any present or future regulation, rule, directive, requirement, request or guideline (whether or not having the force of
law) of any agency, authority, central bank or government department or any self-regulatory or other national or supra-national authority; 

  

	1.3.4	words importing the plural shall include the singular and vice versa; 

  

	1.3.5	references to a time of day are to London time; 

  

	1.3.6	references to a “person” shall be construed as including references to an individual, firm, company, corporation, unincorporated body of persons or any
Government Entity and includes its successors and permitted transferees and assigns; 

  
 19 

	1.3.7	references to a “guarantee” include references to an indemnity or other assurance against financial loss including, without limitation, an obligation to
purchase assets or services as a consequence of an event of default by any other person to pay any Indebtedness and “guaranteed” shall be construed accordingly; 

 

	1.3.8	references to any enactment shall be deemed to include references to such enactment as re-enacted, amended or extended; and 

 

	1.3.9	references to any of the Lender Finance Parties includes its successors and permitted transferees and assigns. 

 

	1.3.10	 references to “indebtedness” means any obligation for the payment or repayment of money, whether as principal or as surety and whether present, future,
actual or contingent. 

  

	2	The Loan and its Purpose 

  

	2.1	Agreement to lend 

Subject to the terms and conditions of this Agreement, and in reliance on each of the representations and warranties made or to be made in
or in accordance with each of the Security Documents: 
  

	2.1.1	each of the Lenders agrees to advance to the Borrower its Commitment of an aggregate principal amount not exceeding the Buyer Credit Maximum Amount to be used by the
Borrower for the purposes referred to in Recital (B); and 

  

	2.1.2	each of the Lenders agrees to advance to the Borrower its Commitment of an aggregate principal amount not exceeding the Commercial Loan Maximum Amount to be used by the
Borrower for the purposes referred to in Recital (C). 

  

	2.2	Drawdown Request 

 The
Borrower may request a Drawing to be advanced in one amount on any Business Day prior to the relevant Availability Termination Date by delivery to the Agent of a duly completed Drawdown Notice not later than 10 a.m. (Paris time) on a Business Day
falling not more than ten (10) and not fewer than three (3) Business Days before the proposed Drawdown Date. A Drawdown Notice shall be effective on actual receipt by the Agent and, once given, shall, subject as provided in clause 13.8, be
irrevocable. 
  

	2.3	Drawings 

  

	2.3.1	The amount of each Drawing shall, subject to the following provisions of this clause 2.3, be for such amount as is specified in the Drawdown Notice for that Drawing.

  

	2.3.2	Drawings may only be made on Business Days falling within the Availability Period. 

 

	2.3.3	Ancillary Cost Advances shall, subject to clause 3, only be available in minimum amounts of one million Dollars ($1,000,000) (provided that this threshold shall not
apply to Ancillary Cost Advances drawn to pay the Ancillary Costs described in part (c) of the definition thereof) and shall only be available for application in or towards payment of expenditure which the Borrower has certified and
evidenced in accordance with clause 3.1.4 and in any event an Ancillary Cost Advance shall only be available if such Ancillary Cost Advance will not, when aggregated with all previous Ancillary Cost Advances, equal a sum in excess of $36,000,000.

  

	2.3.4	The Borrower shall be entitled to draw an Ancillary Cost Advance on the first Drawdown Date up to a maximum amount of $16,750,00021,200,000 for
the purpose of repaying shareholder loans to the extent required to achieve a Borrower’s Leverage Ratio of 4:1. 

  

	2.3.5	Each Ancillary Cost Advance may be made on any date. 

  
 20 

	2.3.6	Contract Instalment Advances shall, subject always to clauses 2.1 and 3, be in the maximum amount not exceeding the relevant instalment amount of the Contract
Price set out in each column (3) of Part A of Schedule 7 as such sumsinstalment amounts may be amended following any permitted increase in the Contract Price and shall only be available for application (a) in
or towards payment of instalments of the Contract Price which have become due and payable by the Borrower pursuant to the Building Contract or (b) in or towards reimbursement to the Borrower of such part of any instalment amount of the Contract
Price as set out in column (3) of Part A of Schedule 7 which has become due and payable by the Borrower pursuant to the Building Contract and which the Borrower has satisfied the Agent has been paid by the Borrower or by the Sponsors on
behalf of the Borrower. 

  

	2.3.7	No Drawing shall be available to the Borrower unless (a) the Agent or the Borrower shall have first received such amount (the “Relevant Amount”)
by way of contributions of Minimum Borrower Shareholders’ Equity and/or Additional Shareholders’ Equity which, when aggregated with the amounts received by the Agent from the Lenders in respect of such Drawing (and in the case of amounts
received by the Borrower, the Agent is satisfied that such amount is or has been or is to be applied in meeting the instalments of Contract Price or Ancillary Cost in respect of which the relevant Drawing is to be applied (and for the avoidance of
doubt the instalments of Ancillary Costs in respect of which Drawings are to be applied shall not when aggregated with all Ancillary Costs in respect of which an Ancillary Cost Advance has been made exceed $36,000,000)) is equal to or greater than
one fifth (1/5th) of the Total Project Cost as at the date of the relevant Drawing (and including such Drawing) and (b) the aggregate of the Drawing and the Relevant Amount shall be not less than the total amount of the relevant Ancillary
Costs and/or the relevant instalment of the Contract Price in respect of which the relevant Drawing is to be applied. 

  

	2.3.8	The aggregate amount which may be drawn down under this Agreement shall never exceed the lesser of (a) 80% of the Total Project Cost and (b) $210,000,000.

  

	2.3.9	Each Drawing (together with the Relevant Amount of the Minimum Borrower Shareholders’ Equity and/or Additional Shareholders’ Equity paid to the Agent pursuant
to clause 2.9 in respect of that Drawing) shall unless the Agent shall determine otherwise be paid by the Agent on behalf of the Borrower directly to the payee(s) in respect of which such Drawing is made provided that in respect of any Ancillary
Cost in respect of which an Ancillary Cost Advance may be made under this Agreement (excluding for these purposes the KEIC Insurance Premium) of less than $1,000,000 in aggregate or where the Agent is satisfied that the Borrower has settled the
amount due to any such payee(s) in full the Agent shall pay that part of the relevant Drawing directly to the Borrower. 

  

	2.3.10	TheSubject to clause 2.3.14, the Agent shall be entitled to set off from any Drawing any interest, fees or commissions or other sums due and
payable by the Borrower to the Lenders or any of them and/or to the Agent and/or to the Security Trustee and/or to the KEIC Agent and/or to the Swap Providers under this Agreement or any of the other Security Documents and to apply the same in
settlement of such interest, fees or commissions or other sums so due and payable. 

  

	2.3.11	The first Drawing (which includes the first Contract Instalment Advance) shall be pro-rated between the Buyer Credit and the Commercial Loan PROVIDED THAT any Ancillary
Cost Advance included in such Drawing, including but not limited to the KEIC Premium, shall be funded 100% by the portion of such Drawing funded by the Commercial Loan. The remaining components of such Drawing shall be funded by such percentage of
the Buyer Credit and Commercial Loan as is required to ensure that such Drawing, taken as a whole, is pro-rated between the Buyer Credit and the Commercial Loan. 

 

	2.3.12	The first Drawing (which inculudes the first Contract Instalment Advance) shall be pro-rated between the Buyer Credit and the Commercial Loan PROVIDED THAT any
Ancillary Cost Advance included in such Drawing, including but not limited to the KEIC Premium, shall be funded 100% by the portion of such Drawing funded by the Commercial Loan.The remaining components of such Drawing shall be funded by such
percentage of the Buyer Credit and Commercial Loan as is required to ensure that Such Drawing, taken as a whole, is pro-rated between the Buyer Credit and the Commercial Loan. 

  
 21 

	2.3.12	2.3.13 Further Drawings (excluding the Drawing due on the Delivery Date) shall each be funded (a) in respect of a Contract Instalment Advance, by
the Buyer Credit in an amount equal to the lesser of US$ 9,240,000 and 50% of the amount of such Contract Instalment Advance with the remainder of such Contract Instalment Advance funded by the Commercial Loan and (b) in respect of any
Ancillary Costs Advance included in such Drawing, 100% by the Commercial Loan. 

  

	2.3.13	2.3.14 The Drawing due on the Delivery Date (which includes the Delivery Date Advance) shall be funded (a) in respect of any Ancillary Costs
Advance included in such Drawing, 100% by the Commercial Loan and (b) in respect of the Delivery Date Advance, by such percentage of the Buyer Credit and Commercial Loan as is required to ensure that, on the Delivery Date, the Loan Outstandings
are pro-rated between the Buyer Credit and the Commercial Loan. 

  

	2.3.14	Where an Ancillary Costs Advance is drawn to pay interest on the Loan (whether the Commercial Loan or the Buyer Credit) falling due for payment and/or accruing on or
before the Delivery Date, the portion of such Ancillary Costs Advance corresponding to such interest shall be funded 100% by the Commercial Loan in accordance with clauses 2.3.11 to 2.3.13 (inclusive) and shall be applied by the Agent in
satisfaction of the Borrower’s obligation to pay such interest (and the Borrower’s obligation to pay such interest shall be deemed to have been satisfied upon the making of such Ancillary Costs Advance). 

 

	2.4	Lenders’ participation 

 Subject to clauses 2 and 3, the Agent shall promptly notify each relevant Lender of the receipt of a Drawdown Notice and of the date on which the Drawing is to be made, following which each relevant
Lender shall advance its proportionate share of the relevant Drawing to the Borrower through the Agent on the relevant Drawdown Date. 
  

	2.5	Availability Termination Date 

 No Lender shall be under any obligation to advance all or any part of its Commitment after the relevant Availability Termination Date. 

 

	2.6	Several obligations 

  

	2.6.1	The obligations of each Lender Finance Party under this Agreement are several. No Lender Finance Party is responsible for the obligations of any other Lender Finance
Party. Even if one or more Lender Finance Parties fails to perform its obligations, the other Lender Finance Parties will continue to perform their obligations and will be able to enforce their rights in respect of the other parties to this
Agreement. 

  

	2.6.2	The obligations of the Borrower under this Agreement are as follows: 

  

	 	(a)	the Borrower will pay to the Security Trustee, when they are due for payment, the full amount of the Loan and all other amounts (including any amounts payable under the
Swap Agreements or any of them, interest, commission and expenses) payable by the Borrower under the Security Documents; 

  

	 	(b)	the Borrower will pay to the Agent for the account of each Lender, when they are due for payment, that proportion of the Loan which was lent by that Lender and all
interest, commission and other amounts payable in relation to it; 

  

	 	(c)	the Borrower will pay to the Agent, when they are due for payment, all amounts owing to it under the Security Documents; 

 

	 	(d)	the Borrower will pay to the KEIC Agent, when they are due for payment, all amounts owing to it under the Security documents; 

 

	 	(e)	the obligations of the Borrower to (on the one hand) the Security Trustee and (on the other hand) each other Lender Finance Party are several; 

  
 22 

	 	(f)	payment either to the Security Trustee or to another Lender Finance Party of an amount which is due to both of them will reduce both of those liabilities by that
amount; and 

  

	 	(g)	if an amount would otherwise be payable under this clause 2.6 to the same person in two different capacities, the Borrower will only have an obligation to pay that
amount once. 

  

	 	2.6.3	Each Lender Finance Party can enforce its rights without joining the Security Trustee or any other Lender Finance Parties. However, the Security Documents listed in
clause 8.1 below can only be enforced by the Security Trustee. 

  

	 	2.7	Application of Loan 

Without prejudice to the obligations of the Borrower under this Agreement, no Lender Finance Party shall be obliged to concern itself with
the application of the Loan by the Borrower. 
  

	 	2.8	Loan facility and control accounts 

 The Agent will open and maintain such loan facility account or such other control accounts as the Agent shall in its discretion consider necessary or desirable in connection with the Loan. 

 

	 	2.9	Minimum Borrower Shareholders’ Equity and Additional Shareholders’ Equity 

The Borrower hereby agrees with the Agent that notwithstanding any other provision of this Agreement subject as contemplated in clause
2.3.7 each Relevant Amount of the Minimum Borrower Shareholders’ Equity and/or Additional Shareholders’ Equity shall be paid to the Agent and each such Relevant Amount paid shall be aggregated with each relevant Drawing and paid by the
Agent pursuant to the provisions of clause 2.3.9. 
  

	 	3	Conditions precedent and subsequent for the Loan 

  

	 	3.1	Conditions precedent 

  

	 	3.1.1	Before any Lender shall have any obligation to advance the first Drawing under the Loan the Borrower shall deliver or cause to be delivered to or to the order of the
Agent all of the documents and other evidence listed in Part 1 of Schedule 3 which shall be delivered not later than 4 Business Days before the day on which the Drawdown Notice for the first Drawing is given save for those documents or other
evidence which are expressly required to be provided on the first Drawdown Date which shall be delivered on such first Drawdown Date. 

  

	 	3.1.2	The obligation of the Lenders to make any Contract Instalment Advance shall be subject to the further condition that the Agent shall have received not later than 4
Business Days before the day on which that Contract Instalment Advance is intended to be made, the documents and evidence specified in Part 2 of Schedule 3 in form and substance satisfactory to the Agent (save for the invoice and the Drawdown Notice
referred to in paragraphs (a) and (e) of Part 2 of Schedule 3 which shall be provided not later than 3 Business Days prior to the relevant Drawdown Date). 

 

	 	3.1.3	The obligation of the Lenders to make the Delivery Date Advance shall be subject to the condition that the Agent, shall have received, on or prior to the relevant
Delivery Date, the documents and evidence specified in Part 3 of Schedule 3 in form and substance satisfactory to the Agent. 

  

	 	3.1.4	 The obligation of the Lenders to make any Ancillary Cost Advance shall be subject to the further condition that the Agent shall have received not later
than 4 Business Days before the drawdown of any Ancillary Cost Advance, invoices or pro-forma invoices or, (save in respect of Ancillary Costs as described in sub-paragraph (f) of the definition thereof in respect of which invoices shall be
required) where invoices or pro-forma invoices cannot be made available by the Borrower, a certificate from the Borrower in form and substance satisfactory to the Agent, in each case evidencing the Ancillary Costs incurred or, in the case of
pro-forma invoices or certificates from the Borrower, to be incurred within the next following period not exceeding 3 Months or other written evidence in each case substantiating to the reasonable satisfaction of the Agent that the Ancillary Costs
in respect of which such Ancillary Cost Advance is requested have been incurred and discharged or will be discharged following the drawdown of the Ancillary Cost Advance. 

  
 23 

	 	3.2	Further conditions precedent 

 The Lenders will only be obliged to advance a Drawing in respect of the Vessel specified in any Drawdown Notice if on the date of the Drawdown Notice and on the proposed Drawdown Date: 

 

	 	3.2.1	no Event of Default, Potential Event of Default or Mandatory Prepayment Event is continuing unremedied or unwaived or would result from the advance of that Drawing;

  

	 	3.2.2	the representations made by the Borrower under clause 4 are true in all material respects; 

 

	 	3.2.3	that Drawing will not, when aggregated with all previous Drawings, increase the outstanding amount of the Loan to a sum in excess of the Maximum Loan Amount and will
not increase the outstanding amount of the Buyer Credit to a sum in excess of the Buyer Credit Maximum Amount or of the Commercial Loan to a sum in excess of the Commercial Loan Maximum Amount; and 

 

	 	3.2.4	the Borrower shall have on or prior to the First Drawing, entered into one or more 12 year forward starting Swap Agreements in form and substance satisfactory to the
Agent with each of the Swap Providers pursuant to which it will hedge not less than one hundred and ninety million Dollars ($190,000,000) of the Loan (representing approximately ninety per cent (90%) of its interest rate exposure under the
Loan) for the period from and including the Delivery Date up to and including the Maturity Date. The Swap Margin applicable to each Swap Agreement entered into between any of the Swap Providers and the Borrower shall be as set out in the Swap Margin
Side Letter. 

  

	 	3.3	Delivery conditions precedent 

  

	 	3.3.1	Whether or not a Drawing is advanced on the Delivery Date, the Borrower undertakes to deliver or to cause to be delivered to the Agent on the Delivery Date the
additional documents and other evidence listed in Part 3 of Schedule 3. 

  

	 	3.3.2	The Borrower shall on the Delivery Date enter into a spot start Swap Agreement or Swap Agreements with each of the Swap Providers to ensure that, together with the
forward starting swap agreements, no less than ninety-five per cent (95%) of its interest rate exposure under the Loan is hedged. 

  

	 	3.4	No Waiver 

 If the Lenders
in their sole discretion agree to advance a Drawing to the Borrower before all of the documents and evidence required by clause 3.1, clause 3.3 and/or clause 3.5 have been delivered to or to the order of the Agent, the Borrower undertakes to deliver
all outstanding documents and evidence to or to the order of the Agent no later than ten (10) Business Days after the Drawdown Date or such other date specified by the Agent acting on the instructions of the Majority Lenders. 

The advance of a Drawing under this clause 3.4 shall not be taken as a waiver of the Lenders’ right to require production of all the
documents and evidence required by clauses 3.1, 3.2 and 3.3. 
  

	 	3.5	Form and content 

 All
documents and evidence delivered to the Agent under this clause 3 shall: 
  

	 	3.5.1	be in form and substance reasonably acceptable to the Agent; and 

  
 24 

	 	3.5.2	if required by any vessel or security registry or in connection with any legal opinion to be provided pursuant to Schedule 3, be certified, notarised, legalised or
attested in a manner acceptable to such registry or person providing the legal opinion. 

  

	 	3.6	Waiver of conditions precedent 

 The conditions specified in this clause 3 are inserted solely for the benefit of the Lenders and may be waived by the Agent (acting on the instructions of the Majority Lenders) in whole or in part with or
without conditions. 
  

	 	4	Representations and Warranties 

  

	 	4.1	Representations and Warranties 

 The Borrower represents and warrants to each of the Lender Finance Parties as follows: 
  

	 	4.1.1	Due Incorporation 

 Each
of the Security Parties is a corporation or limited liability company duly organised or formed under the laws of its jurisdiction of incorporation, organisation or formation (as the case may be) with power to carry on their respective business as
they are now being conducted and to own their respective property and other assets. 
  

	 	4.1.2	Corporate Power 

 The
Borrower has power to execute, deliver and perform its obligations under this Agreement and each of the other Relevant Documents to which it is a party and to borrow the Commitments and each of the other Security Parties has power to enter into the
Relevant Documents to which it is a party and to exercise its rights and perform its obligations under such Relevant Documents; all corporate and other action required by each of the Security Parties to authorise its execution of the Relevant
Documents to which it is a party and the performance by it of its obligations thereunder has been duly taken. 
  

	 	4.1.3	Binding Obligations 

 The
obligations expressed to be assumed by each of the Security Parties in the Relevant Documents to which it is a party are legal, valid and binding obligations, enforceable in accordance with the terms of the Relevant Documents and no limit on any of
their powers will be exceeded as a result of the borrowings, granting of security or giving of guarantees contemplated by the Relevant Documents or the performance by any of them of any of their obligations thereunder. 

 

	 	4.1.4	No conflict with other obligations 

 The execution and delivery of, the performance of its obligations under, and compliance with the provisions of the Relevant Documents to which each is a party by the relevant Security Parties will not:

  

	 	(a)	contravene any existing applicable law, statute, rule or regulation or any judgment, decree or permit to which the Borrower or, any other Security Party is subject;

  

	 	(b)	conflict with, or result in any breach of any of the terms of, or constitute a Potential Event of Default under, any agreement or other instrument to which the Borrower
or, any other Security Party is a party or is subject or by which it or any of its property is bound; 

  

	 	(c)	contravene or conflict with any provision of the constitutional documents of the Borrower or, any other Security Party; or 

  
 25 

	 	(d)	result in the creation or imposition of or oblige the Borrower or any other Security Party, to create any Encumbrance (other than a Permitted Encumbrance) on any of
their respective undertakings, assets, rights or revenues. 

  

	 	4.1.5	No Litigation 

 No
litigation, arbitration or administrative proceeding is taking place, pending or, to the knowledge of the officers of the Borrower, threatened in writing against any of the Security Parties which, in respect of the Security Parties other than the
Borrower, has or could reasonably be expected to have a Material Adverse Effect. 
  

	 	4.1.6	Accounts 

 The certified
true and complete copies of the audited annual accounts and unaudited semi-annual accounts (as applicable) of the Borrower for the period ending on 31 December 2007 and of each Sponsor for the most recent financial year of each such Sponsor and
delivered to the Agent on or prior to the date of this Agreement pursuant to Schedule 3, Part 1, were prepared in accordance with GAAP, give (in conjunction with the notes thereto) a true and fair view of the financial condition of each such party
at the date as of which they were prepared and the results of that party’s operations during the financial period then ended. 
  

	 	4.1.7	No Filing or Stamp Taxes 

It is not necessary to ensure the legality, validity, enforceability or admissibility in evidence of any of the Relevant Documents that
they or any other instrument be notarised, filed, recorded, registered or enrolled with any court, public office or elsewhere in any Relevant Jurisdictionthe jurisdiction of incorporation of the Borrower (other than the
Registrar of Companies for England and Wales, or the relevant maritime registry, to the extent applicable) or that any stamp, registration or similar tax or charge be paid on or in relation to any of such Relevant Documents and each of the Relevant
Documents is in the proper form for enforcement in each Relevant Jurisdiction the jurisdiction of incorporation of the Borrower. 
  

	 	4.1.8	No Immunity 

 None of the
Security Parties or any of their respective assets is entitled to immunity on the grounds of sovereignty or otherwise from any legal action or proceeding including, without limitation, suit, attachment prior to judgement, execution or other
enforcement. 
  

	 	4.1.9	Choice of Law and Judgments 

 The choice of English law to govern the Security Documents (other than the Mortgage and, in the event that the Share Charges are not governed by English law, the Share Charges) and the laws of the Flag
State to govern the Mortgages and, in the event that the Share Charges are not governed by English law, the governing law of the Share Charges and the submission by the Security Parties to the jurisdiction of the English courts in respect of the
Security Documents (other than the Mortgage and, in the event that the Share Charges are not governed by English law, the Share Charges) are valid and binding. 
  

	 	4.1.10	Consents Obtained 

 Every
consent, Authorisation, licence or approval of, or registration with or declaration to, governmental or public bodies or authorities or courts required by any Security Party to authorise, or required by each such party in connection with, the
execution, delivery, validity, enforceability or admissibility in evidence of each of the Relevant Documents or the performance by each such party of its obligations under the Relevant Documents to which each is a party has been obtained or made
(other than consents, Authorisations, licences, approvals, registrations or declarations that, as at the date of the representation, are not required to be obtained) and is in full force and effect and there has been no default in the observance of
any of the conditions or restrictions (if any) imposed in, or in connection with, any of the same. 

  
 26 

	 	4.1.11	No Undisclosed Liabilities 

The Borrower has no material liabilities (contingent or otherwise) which were not disclosed in the accounts referred to in clause 4.1.6
(or by the notes thereto) or reserved against therein nor any unrealised or anticipated losses arising from commitments entered into by it which were not so disclosed or reserved against therein. 

 

	 	4.1.12	Money Laundering 

 No
breach of any law or regulatory measure relating to “money laundering” as defined in Article 1 of the Directive (91/308/EEC) of the Council of the European Communities will result from the borrowing of the Loan by the Borrower or from
the performance by any of the Security Parties of any of their obligations under any of the Relevant Documents to which each is a party. 
  

	 	4.1.13	Financial Indebtedness 

Except as set forth in Exhibit A, other than in respect of the Loan pursuant to this Agreement or as otherwise permitted by this
Agreement, it has not created, incurred, assumed or allowed to exist any Financial Indebtedness, entered into any finance lease or undertaken any capital commitment. 
  

	 	4.1.14	Environmental Matters 

Except as may already have been disclosed by the Borrower to the Agent in writing: 

 

	 	(a)	all Environmental Laws applicable to the Vessel have been complied with by each Environmental Affiliate and all consents, licences and approvals required under such
Environmental Laws have been obtained and complied with by each Environmental Affiliate (other than such consents, licences and approvals that, as at the date of the representation, are not required to be obtained); and 

 

	 	(b)	no Environmental Claim has been made or threatened against the Borrower or the Vessel and no Environmental Claim in respect of the Vessel has been made or threatened
against any other Environmental Affiliate or is pending against any such Environmental Affiliate or the Vessel and which has not been fully satisfied and which would or might reasonably result in liabilities in excess of an aggregate of $1,000,000;
and 

  

	 	(c)	there has been no Environmental Incident which could or might reasonably result in claims in excess of an aggregate of $1,000,000. 

 

	 	4.1.15	Pari Passu 

 The
obligations of the Security Parties under the Security Documents are direct, general and unconditional obligations and rank at least pari passu with all the Security Parties’ other present and future unsecured unsubordinated indebtedness other
than obligations mandatorily preferred by law and not contract. 
  

	 	4.1.16	No Deductions or Withholding 

 No Taxes are imposed by way of or withholding or otherwise from any payment to be made by any Security Party under any of the Security Documents to which it is a party. 

 

	 	4.1.17	Information 

 The
information, exhibits and reports furnished by any Security Party to any of the Lender Finance Parties in connection with the negotiation and preparation of the Security Documents are true and accurate in all material respects and not misleading, do
not omit material facts and all reasonable enquiries have been made to verify the facts and statements contained therein and the Borrower is not aware of any material facts or circumstances which have not been disclosed and which might, if
disclosed, have reasonably been expected to adversely affect the decision of a person considering whether or not to make loan facilities of the nature contemplated by this Agreement available to the Borrower and/or to enter into the transactions
contemplated in this Agreement and the other Security Documents, Provided that, the Borrower does not make the representations in this clause 4.1.17 in respect of information, exhibits or reports regarding Angola LNG, the Angola LNG Project or the
Time Charterer save that such information, exhibits or reports which have been provided by the Borrower to the Lender Finance Parties have been provided by the Borrower in good faith. 

  
 27 

	 	4.1.18	Solvency 

  

	 	(a)	None of the Security Parties is unable, or admits or has admitted its inability, to pay its debts or has suspended making payments in respect of any of its debts.

  

	 	(b)	None of the Security Parties by reason of actual or anticipated financial difficulties, has commenced, or intends to commence, negotiations with one or more of its
creditors with a view to rescheduling any of its indebtedness. 

  

	 	(c)	No moratorium has been, or may, in the reasonably foreseeable future be, declared in respect of any indebtedness of any Security Party. 

 

	 	4.1.19	No Winding-up 

 None of
the Security Parties has taken any corporate action nor have any other steps been taken or legal proceedings been started or (to the best of the Borrower’s knowledge and belief) threatened against any Security Party for its winding-up,
dissolution, administration or reorganisation or for the appointment of a receiver, administrator, administrative receiver, trustee or similar officer of it or of any or all of its assets or revenues which (in relation to Security Parties other than
the Borrower) might have a Material Adverse Effect. 
  

	 	4.1.20	Event of Default/no other Defaults 

  

	 	(a)	None of the Security Parties is in material breach of or in default under any agreement to which it is a party or which is binding on it or any of its assets.

  

	 	(b)	No Event of Default or Potential Event of Default is continuing unremedied or unwaived. 

 

	 	4.1.21	Ownership of the Borrower 

The Sponsors, directly or indirectly, legally and beneficially own all of the shares in the Borrower and will (subject to the provisions
of clause 9.2.17) continue to, directly or indirectly, own all of the shares in the Borrower in the following percentages: 
  

					
	 Teekay :-
	  	 	33	% 
		
	 NYK :-
	  	 	33	% 
		
	 Mitsui :-
	  	 	34	% 

  

	 	4.1.22	No Default under Building Contract or Refund Guarantee 

 The Borrower is not in default of any of its obligations under the Building Contract or any of its obligations upon the performance or observance of which depend the continued liability of the Refund
Guarantor in accordance with the terms of the Refund Guarantee. 
  

	 	4.1.23	No Encumbrance in respect of pre-delivery security 

 The Borrower has not previously charged, encumbered or assigned the benefit of any of its rights, title and interest in or to the Building Contract, the Refund Guarantee, the Supervision Agreement, the
Swap Agreements or the Depot Spares Sharing Agreement and such benefit and all such rights, title and interest are freely assignable and chargeable in the manner contemplated by the Security Documents. 

  
 28 

	 	4.1.24	The Vessel 

 The Vessel
will on the Delivery Date be: 
  

	 	(a)	in the absolute ownership of the Borrower who will on and after the Delivery Date thereof be the sole, legal and beneficial owner of the Vessel;

  

	 	(b)	registered in the name of the Borrower under the laws and flag of the Bahamas; 

 

	 	(c)	operationally seaworthy and in every way fit for service; and 

  

	 	(d)	classed with the classification referred to in clause 9.6.3(b) free of any overdue recommendations and conditions affecting the Vessel’s class of the
Classification Society. 

  

	 	4.1.25	Vessel’s employment 

The Vessel will not on or before the Delivery Date thereof be subject to any charter or contract other than the Time Charter or to any
agreement to enter into any charter or contract which, if entered into after the date of the Mortgage would have required the consent of the Agent or Security Trustee and on the Delivery Date thereof there will not be any agreement or arrangement
whereby the Earnings may be shared with any other person. 
  

	 	4.1.26	Freedom from Encumbrances 

Neither the Vessel nor its Earnings, Insurances or Requisition Compensation, the Time Charter, the Accounts, nor the Depot Spares Sharing
Agreement, nor any other properties or rights which are, or are to be, the subject of any of the Security Documents nor any part thereof will be, on the Delivery Date of the Vessel, subject to any Encumbrance other than any Permitted Encumbrance.

  

	 	4.1.27	Copies true and complete 

The copies of each of the Time Charter, the Building Contract, the Refund Guarantee, the Supervision Agreement, the Depot Spares Sharing
Agreement, the Tripartite Agreement and the Management Agreement, and the Sub-Management Agreement delivered or to be delivered to the Agent are or will when delivered be, a true and complete copies of such documents, will when delivered constitute
valid and binding obligations of the parties thereto enforceable in accordance with its terms and there have been no material amendments or variations to or defaults under the Building Contract and there have been no amendments or variations to or
defaults under the Time Charter. 
  

	 	4.2	Repetition of representations and warranties 

 On the Execution Date and, in respect of the Relevant Documents other than this Agreement on the execution date of such other Relevant Document, and as of each Drawdown Date and on each Interest Payment
Date the Borrower shall (a) be deemed to repeat the representations and warranties in clause 4.1 as if made with reference to the facts and circumstances existing on such day and (b) in respect of clause 4.1.6 shall be deemed to refer to
the then latest audited financial statements delivered to the Agent pursuant to clause 9.1.5. 
  

	 	4.3	Representations Limited 

The representations and warranties of the Borrower in this clause 4 are subject to: 

 

	 	4.3.1	the principle that equitable remedies are remedies which may be granted or refused at the discretion of the court; 

  
 29 

	 	4.3.2	the limitation of enforcement by laws relating to bankruptcy, insolvency, liquidation, reorganisation, court schemes, moratoria, administration and other laws generally
affecting or limiting the rights of creditors; 

  

	 	4.3.3	the time barring of claims under any applicable limitation acts; 

  

	 	4.3.4	the possibility that a court may strike out provisions for a contract as being invalid for reasons of oppression, undue influence or similar; 

 

	 	4.3.5	any other reservations or qualifications of law expressed in the legal opinions obtained by the Agent as referred to in Schedule 3 Part 1, paragraph (I) in
connection with this Agreement or the Security Documents; and 

  

	 	4.3.6	the representations and warranties made on the Execution Date in respect of the Relevant Documents shall expressly be limited to this Agreement (and none of the other
Security Documents) and only those Project Documents which, as at the Execution Date, have been executed by the Borrower. 

  

	 	5	Repayment and Prepayment 

  

	 	5.1	Repayment of Loan 

 The
Borrower agrees: 
  

	 	5.1.1	to repay the Buyer Credit to the Agent for the account of the Lenders by forty eight (48) consecutive annuity style quarterly Repayment Instalments in the amounts,
subject to the provisions of this Agreement, set out in Part B of Schedule 7. The first Repayment Instalment will fall due on the date falling three (3) Months after the Delivery Date and each succeeding Repayment Instalment shall be
payable quarterly in arrears at three (3) Monthly intervals thereafter save for the final Repayment Instalment which shall be payable on the Maturity Date; and 

 

	 	5.1.2	to repay the Commercial Loan by one (1) instalment to be paid on the Maturity Date. 

 

	 	5.2	Reduction of Repayment Instalments 

 If, following the Availability Termination Date, the aggregate amount advanced to the Borrower under the Buyer Credit is less than the Buyer Credit Maximum Amount, the amount of each Repayment Instalment
of the Buyer Credit shall be reduced pro rata so that the aggregate sum of all such Repayment Instalments shall be equal to the aggregate amount of the Buyer Credit actually advanced. 

 

	 	5.3	Reborrowing 

 The Borrower
may not reborrow any part of the Loan which is repaid or prepaid. 
  

	 	5.4	Prepayment and Cancellation 

  

	 	5.4.1	The Borrower may prepay, without premium or penalty but subject to clause 5.10, the Loan Outstandings in whole or in part, or cancel the Loan in whole or in part, in
each case in a minimum amount of five million Dollars ($5,000,000) or any larger sum which is an integral multiple of one million Dollars ($1,000,000) (or in either case as otherwise may be agreed by the Agent) and provided that the Borrower has
first given to the Agent not fewer than ten (10) days prior written notice in respect of a prepayment of all or part of the Loan Outstandings or fifteen (15) days in respect of a cancellation in whole or part of the Commitment in each such
case expiring on a Business Day of their intention to do so. Any notice pursuant to this clause 5.4 once given shall be irrevocable and shall (in the case of a prepayment) oblige the Borrower to make the prepayment referred to in the notice on the
Business Day specified in the notice, together with all interest accrued on the amount prepaid and all accrued and unpaid Commitment Fees up to and including that Business Day and any and all other amounts then due and payable under this Agreement
and any of the other Security Documents including, without limitation, any sums payable under the indemnity in clause 15 and all amounts due and payable under the Swap Agreements. Any cancellation of part (but not the whole) of the Commitment shall
be subject to the condition that the Borrower has demonstrated to the satisfaction of the Agent (acting reasonably) that it will have sufficient funds to comply with its obligations under the Relevant Documents following any such cancellation.

  
 30 

	 	5.5	Mandatory Prepayment on Total Loss 

 In the event that the Vessel becomes a Total Loss on or following the Delivery Date thereof, on the earlier to occur of (a) the date of receipt of the proceeds of the Total Loss and (b) the date
falling one hundred and eighty (180) days after the occurrence of the Total Loss (the “Reduction Date”), the Borrower shall prepay the Loan together with all interest accrued thereon up to and including the day of prepayment
and all other amounts then due and payable under this Agreement or any of the other Security Documents including, without limitation, any sums payable under the indemnity in clause 15 and all amounts due and payable under the Swap Agreements.

  

	 	5.6	Prepayment on Non Delivery/Building Contract default/termination 

 In the event that there is a material breach by the Builder of the Building Contract that has not been cured within the applicable grace period provided therein, or the Building Contract is cancelled,
terminated, rescinded or frustrated for any reason that has not been cured within the applicable grace period provided therein or if the Builder assigns, transfers, sells or otherwise disposes of any of its right, title or interest in or to the
Building Contract or the Vessel or purports to do so or takes any action to so assign, transfer, sell or otherwise dispose of any or all such rights, title or interest or, prior to the Delivery Date the Vessel becomes a Total Loss the Borrower
shall, if so requested by the Agent in writing, and without prejudice to the Agent’s rights pursuant to clause 10.1 and/or the rights of the Security Trustee under the Security Documents where any of the events described above constitute an
Event of Default, be obliged to prepay the Loan immediately together with all interest accrued thereon up to and including the day of prepayment and all other amounts then due and payable under this Agreement or any of the other Security Documents
including, without limitation, any sums payable under the indemnity in clause 15 and all amounts due and payable under the Swap Agreements and the undrawn Commitments shall be cancelled. 

 

	 	5.7	Prepayment on Termination of Refund Guarantee 

 If, prior to the delivery to and acceptance by the Borrower from the Builder of the Vessel, the Refund Guarantee is repudiated, cancelled, amended without the Agent’s prior written consent (acting on
the Instructions of all Lenders), rescinded or otherwise terminated, the Loan shall become prepayable and shall be prepaid immediately and without demand together with all interest accrued thereon up to and including the date of prepayment and all
other amounts then due and payable under this Agreement or any of the other Security Documents including, without limitation, any sums payable under the indemnity in clause 15 and all amounts due and payable under the Swap Agreements. 

 

	 	5.8	Additional Mandatory Prepayment Events 

 Upon the occurrence of any of the following events the Loan shall immediately become repayable and the Borrower shall immediately prepay the Loan together with all interest accrued thereon up to and
including the date of prepayment together with all other amounts then due and payable under this Agreement and the other Security Documents including, without limitation, any indemnity sums payable under clause 15 and all amounts due and payable
under the Swap Agreements. 
  

	 	5.8.1	Non-Delivery of the Vessel: the Vessel is not delivered to, and accepted by, the Borrower under the Building Contract and/or by the Time Charterer under the Time
Charter prior to the date falling 290 days after the Scheduled Delivery Date (or such later date as the Agent acting on the instructions of the Majority Lenders (acting in their absolute discretion), may agree in writing); or

  
 31 

	 	5.8.2	Sale/Early Termination: the Vessel is sold or the chartering of the Vessel is terminated early pursuant to the exercise by the Time Charter of its rights under
the Time Charter; or 

  

	 	5.8.3	Invalidity: (i) any of the Security Documents or the Refund Guarantee shall at any time and for any reason become invalid, illegal or unenforceable or
impossible to perform or cease to remain in full force and effect; or (ii) any of the Project Documents shall at any time and for any reason become invalid, illegal or unenforceable or impossible to perform or cease to remain in full force and
effect unless (A) in respect of the Security Documents, the relevant Security Document is amended or replaced to the reasonable satisfaction of the Agent acting on the instructions of all of the Lenders forthwith in the case of this Agreement,
the Mortgage, the Refund Guarantee and the Deed of Covenants or within 14 days in the case of any other Security Document and (B) where any such events have occurred in respect of the Time Charter, the Borrower has, within 30 days of the
occurrence of such events entered into a new time charter and with a new time charterer in each case in all respects satisfactory to the Agent acting on the instructions of all the Lenders and to KEIC; or 

 

	 	5.8.4	Termination of Time Charter: the Time Charter is terminated by the Borrower or the Time Charterer following the occurrence of a breach of the Time Charter
entitling it to take such action or is cancelled or becomes frustrated for any reason whatsoever unless the Borrower has within 30 days of the date of such occurrence entered into a replacement time charter and with a new time charterer in each case
in all respects satisfactory to the Agent (acting on the instructions of all Lenders); or 

  

	 	5.8.5	Time Charterer failure to pay: the Time Charterer fails to pay any sum due and payable by it to any of the Lender Finance Parties or to the Borrower under any of
(a) the Security Documents or (b) the Project Documents to which it is a party at the time, in the currency and in the manner stipulated thereunder unless, where such failure to pay is a failure to pay any sum due and payable by it under
any Project Document, following expiry of any applicable grace period thereunder, such failure in the opinion of the Agent (acting on the instructions of all Lenders (acting reasonably)) does not and will not be likely to have a Material Adverse
Effect; or 

  

	 	5.8.6	Time Charter’s breach: the Time Charterer commits any breach of or omits to observe any of its obligations or undertakings expressed to be assumed by it
under (a) any of the Security Documents (and such failure is not remedied within fifteen (15) days after the date the Agent has given notice thereof to the Borrower and the Time Charterer) and/or (b) any of the Project Documents to
which it is a party (other than those referred to in clause 5.8.5) unless, where such breach or omission has occurred under a Project Document following expiry of any applicable grace period therein, such breach or omission, in the opinion of the
Agent (acting on the instructions of all Lenders (acting reasonably)), does not and will not be likely to have a Material Adverse Effect. 

  

	 	5.8.7	War: if the country of registration of the Vessel becomes involved in war (whether or not declared) or civil war or is occupied by any other power and the Agent
reasonably considers that, as a result, the security conferred by the Security Documents is materially prejudiced. 

  

	 	5.8.8	Failure to Pay: the Builder or the Refund Guarantor fails to pay any amount payable by it under any of the Security Documents or the Refund Guarantee at the
time, in the currency and otherwise in the manner specified therein (and so that, for this purpose, sums payable on demand shall be treated as having been paid at the stipulated time if paid within five (5) days of demand) unless in respect of
scheduled payments the Borrower demonstrates to the satisfaction of the Agent that such failure has occurred by reason solely of banking error and such sum remains unpaid for no longer than five (5) days after the date on which it receives
notice from the Agent of such failure; or 

  

	 	5.8.9	Other Obligations: the Builder or the Refund Guarantor fails duly to perform or comply with any other term or condition of any other Security Document to which
it is a party when such failure is in the opinion of the Agent (acting on the instructions of the Majority Lenders) remediable (other than those referred to in clauses 5.8.7, 5.8.8, 5.8.21 or 5.8.22) and such failure is not remedied within fifteen
(15) days after the Agent has given notice thereof to the Builder or the Refund Guarantor, as the case may be (or such longer period as the Agent (acting on the instructions of the Majority Lenders) may specify or agree); or

  
 32 

	5.8.10	Litigation: any litigation, arbitration or administrative action or proceeding is commenced prior to Delivery against the Builder or the Refund Guarantor or any
of their property, undertakings or assets before any court, arbitrator or administrative agency or authority which, if adversely determined, would have in the reasonable opinion of the Agent a Material Adverse Effectmaterial
adverse effect on the financial condition of the Builder or, as the case may be, the Refund Guarantor or their ability to comply with their material obligations under the Relevant Documents to which they are party unless:

  

	 	(a)	the Borrower demonstrates in writing to the Agent (who shall act reasonably in considering such matters) to the Agent’s satisfaction, that such litigation,
arbitration or administrative action or proceeding is or may reasonably be considered to be vexatious or frivolous; or 

  

	 	(b)	it is dismissed or irrevocably stayed within thirty (30) days of commencement; 

 

	5.8.11	Legal process: 

  

	 	(a)	any final judgment or order greater than two million Dollars ($2,000,000) made prior to the Delivery Date against the Builder or the Refund Guarantor
is not stayed or complied with within twenty (20) Business Days or a creditor attaches or takes possession of, or a distress, execution, sequestration or other process is levied or enforced upon or sued out against, all or a substantial part of
(in the reasonable opinion of the Agent) the undertakings, assets, rights or revenues prior to delivery of the Builder or the Refund Guarantor and is not discharged within twenty (20) Business Days and, in each such case above, the event
described above has or might reasonably be likely to have a material adverse effect on the financial condition of the Builder or, as the case may be, the Refund Guarantor or their ability to comply with their material obligations under the Relevant
Documents to which they are party; or 

  

	 	(b)	any final judgment or order made against any Security Party (other than the Borrower and (following the Delivery Date) the Supervisor) is not stayed or complied with
within twenty (20) Business Days or a creditor attaches or takes possession of, or a distress, execution, sequestration or other process is levied or enforced upon or sued out against, all or substantially all of (in the reasonable opinion of
the Agent) the undertakings, assets, rights or revenues of any Security Party (other than the Borrower and (following the Delivery Date) the Supervisor) and is not discharged within twenty (20) Business Days and, in each such case above, the
event described above has or might reasonably be likely to have a Material Adverse Effect; or 

  

	 	5.8.12	Insolvency: prior to the Delivery Date, the Builder or the Refund Guarantor is unable or admits inability to pay its debts as they fall due; suspends making
payments on any of its debts or announces an intention to do so; becomes insolvent; has assets the value of which is less than the value of its liabilities; or suffers the declaration of a moratorium in respect of any of its indebtedness; or

  

	 	5.8.13	Winding up: any corporate action, legal proceedings or other procedure or step is taken for the purpose of winding up prior to Delivery of the Builder or the
Refund Guarantor or an order is made or resolution passed for the winding up, prior to Delivery of the Builder or the Refund Guarantor or a notice is issued convening a meeting for the purpose of passing any such resolution, provided however that,
in the case only of an order for winding-up, the occurrence of such event shall not constitute a mandatory prepayment event if such winding-up has commenced as part of a process of a fully-solvent reorganisation, previously approved by the Agent
acting on the instructions of the Majority Lenders and which shall not have a Material Adverse Effectmaterial adverse effect on the financial condition of the Builder or, as the case may be, the Refund Guarantor or their ability
to comply with their material obligations under the Relevant Documents to which they are party; or 

  
 33 

	5.8.14	Administration: any petition is presented, notice given or other step is taken for the purpose of the appointment of an administrator prior to Delivery of the
Builder or the Refund Guarantor or an administration order is made prior to Delivery in relation to the Builder or the Refund Guarantor; or 

  

	5.8.15	Appointment of receivers and managers: any administrative or other receiver is appointed prior to Delivery of the Builder or the Refund Guarantor or any part of
its assets and/or undertaking or any other steps are taken to enforce any Encumbrance over all or any part of the assets prior to delivery of the Builder or the Refund Guarantor; or 

 

	5.8.16	Compositions: any corporate action, legal proceedings or other procedures or steps are taken, or negotiations commenced prior to Delivery, by the Builder or the
Refund Guarantor or by any of its creditors with a view to the general readjustment or rescheduling of all or a material part of its indebtedness or to proposing any kind of composition, compromise or arrangement involving such company and any of
its creditors; or 

  

	5.8.17	Analogous proceedings: there occurs, prior to Delivery in relation to the Builder or the Refund Guarantor, in any country or territory in which any of them
carries on business or to the jurisdiction of whose courts any part of their assets is subject, any event which, in the reasonable opinion of the Agent, appears in that country or territory to correspond with, or have an effect equivalent or similar
to, any of those mentioned in clauses 10.2.9 to 10.2.15 (inclusive) (other than clause 10.2.10) or prior to Delivery the Builder or the Refund Guarantor otherwise becomes subject, in any such country or territory, to the operation of any law
relating to insolvency, bankruptcy or liquidation; or 

  

	5.8.18	Repudiation: the Supervisor, the Builder or the Refund Guarantor repudiates any Security Document or Project Document to which it is a party or does or causes to
be done any act or thing evidencing an intention to repudiate any such Security Document or the Project Document if the validity or enforceability of any of the Security Documents and the Project Documents (other than the Refund Guarantee) shall at
any time and for any reason be contested by the Supervisor, the Builder or the Refund Guarantor which is a party thereto, or if the Supervisor, the Builder or the Refund Guarantor shall deny that it has any, or any further, liability thereunder; or

  

	5.8.19	Cessation of business: prior to Delivery, the Builder or the Refund Guarantor suspends or ceases to carry on its business; or 

 

	5.8.20	Seizure: all or a material part of the undertaking, assets, rights or revenues of, or shares or other ownership interests, prior to Delivery, in the Builder and
the Refund Guarantor are seized, nationalised, expropriated or compulsorily acquired by or under the authority of any government; or 

  

	5.8.21	Arrest: the Vessel is arrested, confiscated, seized, taken in execution, impounded, forfeited, detained in exercise or purported exercise of any possessory lien
or other claim or otherwise taken from the possession of the Borrower and the Borrower shall fail to procure the release of the Vessel within a period of 30 days thereafter; or 

 

	5.8.22	Supervision Agreement: notice of termination under the Supervision Agreement is served for any reason whatsoever or the Supervision Agreement is varied in any
manner not permitted pursuant to the Security Documents unless (a) in the case of termination the same is replaced with a supervision agreement on substantially the same or other terms acceptable to the Agent or (b) in the case of
variation the same is revised, or amended on terms acceptable to the Agent, and in any such case under (a) or (b) within 30 days. 

  
 34 

	5.9	Cessation of KEIC Buyer Credit Policy 

 If, for any reason (other than as referred to in clause 10.2.25), the obligations of KEIC under the KEIC Buyer Credit Policy shall terminate, become unenforceable or otherwise cease to be in full force
and effect and the Borrower has not replaced the KEIC Buyer Credit Policy with similar insurance on terms and conditions satisfactory to the Agent (acting on the instructions of all Lenders in their sole and absolute discretion) forthwith upon
receipt of written notice of such termination, unenforceability or cessation of effectiveness, the Borrower shall prepay the Loan in full together with accrued interest to the date of prepayment and all other sums then due and payable, any portion
of the KEIC premium which is then due and payable and all other sums then due and payable under this Agreement and the other Security Documents or any of them including without limitation any sum payable under the indemnity in clause 15).

  

	5.10	Prepayment indemnity 

 If
the Borrower shall make a prepayment on a Business Day other than the last day of an Interest Period, it shall pay to the Agent on behalf of the Lenders any amount which is necessary to compensate the Lenders for any Break Costs incurred by the
Agent or any of the Lenders as a result of the prepayment in question but otherwise without penalty or premium, Provided always that the Borrower shall be entitled to payment by the Lenders of any Break Gains while no Event of Default has occurred
which is continuing unremedied or unwaived. 
  

	5.11	Application of prepayments 

Any prepayment in an amount less than the Lender Indebtedness shall be applied pro-rata between the Buyer Credit and the Commercial Loan
and, in the case of the Buyer Credit shall be applied in reducing the then future Repayment Instalments in inverse order of maturity. 
  

	5.12	Effect of Prepayment/Cancellation on Swap Agreements 

 In the event of any prepayment or, as the case may be, cancellation of the Loan, the exposure of the Swap Providers under the Swap Agreements shall, if the Loan Outstandings is less than the aggregate of
the notional amounts of the Swap Agreements, be reduced by an equivalent amount. 
  

	6	Interest 

  

	6.1	Interest Periods 

 The
period during which any Drawing shall be outstanding pursuant to this Agreement shall be divided into consecutive Interest Periods of three (3) Months’ duration or such other duration as may be agreed by the Borrower and the Agent (acting
on the instructions of all Lenders). 
  

	6.2	Beginning and end of Interest Periods 

 The first Interest Period in respect of the first Drawing shall begin on the Drawdown Date of that Drawing and shall end on the last day of the Interest Period. The first Interest Period in respect of
each subsequent Drawing shall begin on the Drawdown Date of that Drawing and end on the last day of the current Interest Period of the Loan. Any subsequent Interest Period in respect of each Drawing shall commence on the day following the last day
of its previous Interest Period and shall end on the last day of its current Interest Period. 
  

	6.3	Interest Periods to meet Repayment Date and Maturity Date 

 If an Interest Period would otherwise end on a date after the next Repayment Date, that Interest Period shall end on the next Repayment Date. If an Interest Period would otherwise end on a date after the
Maturity Date, that Interest Period shall end on the Maturity Date. 

  
 35 

	6.4	Interest rate 

 During
each Interest Period, interest shall accrue on the Loan at the rate determined by the Agent to be the aggregate of (a) the relevant Margin and (b) LIBOR determined at 11:00 am (London time) on the second London Business Day prior to the
beginning of the Interest Period. The Agent shall notify the Borrower in writing of the applicable interest rate for the relevant Interest Period on the date of determination. 

 

	6.5	Accrual and payment of interest 

 During the Facility Period, interest shall accrue from day to day, shall be calculated on the basis of a 360 day year and the actual number of days elapsed (or, in any circumstance where market practice
differs, in accordance with the prevailing market practice) and shall be paid by the Borrower to the Agent on behalf of the Lenders on the last day of each Interest Period and additionally, during any Interest Period exceeding three Months, on the
last day of each successive three Month period after the beginning of that Interest Period. 
  

	6.6	Ending of Interest Periods 

Subject to clause 6.3, if any Interest Period would end on a day which is not a Business Day, that Interest Period shall end on the next
succeeding Business Day (unless the next succeeding Business Day falls in the next calendar Month, in which event the Interest Period in question shall end on the immediately preceding Business Day). 

 

	6.7	Consolidation and division of Loans 

 If two or more Interest Periods: 
  

	 	(a)	relate to Loans; and 

  

	 	(b)	end on the same date, 

 those
loans will be consolidated into, and treated as, a single Loan on the last day of the Interest Period. 
  

	6.8	Default Rate 

 Each Unpaid
Sum shall, from the date of the non-payment, bear interest up to the date of actual payment (both before and after judgment) at the Default Rate, compounded at such intervals as the Agent shall in its reasonable discretion determine, which interest
shall be payable from time to time by the Borrower to the Agent on behalf of the Lenders on demand. 
  

	6.9	Determinations conclusive 

Each determination of an interest rate made by the Agent in accordance with clause 6 shall (save in the case of manifest error or on any
question of law) be final and conclusive. 
  

	6.10	Mandatory Costs 

 The
Borrower shall reimburse the Agent on demand for any Mandatory Costs relating to the Loan incurred by a Lender as a result of funding its Commitment of the Loan. 
  

	7	Fees 

 The Borrower shall
pay the following fees: 

  
 36 

	7.1	Arrangement fee 

 The
Borrower shall pay to the Agent, for the account of the Lenders, arrangement fees in the amounts and at the times agreed in the Arrangement Fee Letter. 
  

	7.2	Commitment fee 

 The
Borrower shall pay to the Agent: 
  

	7.2.1	(for the account of the Lenders in proportion to their Buyer Credit Commitments) a commitment fee computed at the rate of zero point two five per cent (0.25%) per annum
on the daily undrawn and uncancelled amount of the Buyer Credit Maximum Amount from time to time; and 

  

	7.2.2	for the account of the Lenders (in proportion to their Commercial Loan Commitments) a commitment fee computed at the rate of zero point four five per cent (0.45%) per
annum on the daily undrawn and uncancelled amount of the Commercial Loan Maximum Amount from time to time, 

 in
each case from the date of this Agreement until the earlier to occur of the Drawdown Date in respect of the final Drawing and the Availability Termination Date. The accrued commitment fees are payable in arrears on the last day of each successive
period of three Months from the date of this Agreement and on such Availability Termination Date. 
  

	7.3	Agency fee 

 The Borrower
shall pay to the Agent, the Security Trustee and the KEIC Agent (in each case, for its own account) an agency fee in the amount and at the times agreed in the Agency Fee Letter. 

 

	7.4	Documentation Agency Fee 

The Borrower shall pay to Calyon (for its own account) a documentation agency fee in the amount and at the times agreed in the
Documentation Agency Fee Letter. 
  

	7.5	Account Bank Fee 

 The
Borrower shall pay to the Account Bank (for its own account) an account bank fee in the amount and at the times agreed in the Account Bank Fee Letter. 
  

	7.6	KEIC Insurance Premium 

  

	7.6.1	The Borrower agrees that it shall pay to the KEIC Agent, on the date of the first Drawing under the Commercial Loan, an amount equal to the KEIC Insurance Premium to be
paid by the KEIC Agent to KEIC. 

  

	7.6.2	The Borrower agrees that its obligation to make the payment described in clause 7.6.1 above or any part of it shall be an absolute obligation and without limitation,
shall not be affected by any failure to draw down funds under this Agreement or the prepayment or acceleration of any Loan. Neither the KEIC Insurance Premium nor any part of it shall be refundable to the Borrower under any circumstances. If and to
the extent that the KEIC Agent subsequently receives from KEIC a refund of the KEIC Insurance Premium or any part thereof, the KEIC Agent shall account to the Agent for the amount of the refund received by the KEIC Agent less any costs and expenses
suffered or incurred by the KEIC Agent in recovering and/or transferring such refunded amount to the Agent for application by the Agent in prepayment of the Commercial Loan Outstandings in whole or in part. 

 

	7.6.3	Without prejudice to the Borrower’s obligations under clauses 7.6.1 and 7.6.2, the Lender Finance Parties and the Borrower acknowledge that the first Drawdown
under the Commercial Loan shall be utilised, inter alia, to enable the Borrower to satisfy its obligation under clause 7.6.1. The Borrower instructs the Agent, in accordance with clause 2.3.9, to pay an amount equal to the KEIC Insurance Premium
from the first Drawing under the Commercial Loan to the KEIC Agent. Upon receipt by the KEIC Agent of such amount, the Borrower shall have satisfied its obligation under clause 7.6.1. 

  
 37 

	8	Security, Accounts and Application of Moneys 

  

	8.1	Security Documents 

 As
security for the repayment of the Indebtedness, the Borrower shall, subject to the terms and conditions of this Agreement, execute and deliver to the Security Trustee or cause to be executed and delivered to the Security Trustee the following
documents in such forms and containing such terms and conditions as the Security Trustee shall require: 
  

	8.1.1	first priority deed of assignment of the Building Contract and Refund Guarantee; 

 

	8.1.2	a first priority statutory mortgage over the Vessel together with a collateral deed of covenants; 

 

	8.1.3	a first priority tripartite deed of assignment of the Insurances, Earnings and Requisition Compensation of the Vessel from the Borrower and the Manager and the
Sub-Manager; 

  

	8.1.4	first priority deed of charge over each of: 

  

	 	(a)	the Revenue Account; 

  

	 	(b)	the Dry Docking Reserve Account; 

  

	 	(c)	the Retention Account; 

  

	 	(d)	the Debt Service Reserve Account; and 

  

	 	(e)	the Dividend Lock-up Account; 

  

	8.1.5	first priority deed of assignment over each of: 

  

	 	(a)	the Supervision Agreement; 

  

	 	(b)	the Time Charter; 

  

	 	(c)	the Depot Spares Sharing Agreement; 

  

	 	(d)	the Management Agreement and the Sub-Management Agreement; 

  

	 	(e)	the Swap Agreements; 

  

	 	(f)	the Tripartite Agreement; 

  

	8.1.6	a first priority charge over the entire issued share capital of the Borrower; 

 

	8.1.7	the Letter of Sponsors Undertakings; 

  

	8.1.8	the Manager’s Undertaking; and 

  

	8.1.9	the Sub-Manager’s Undertaking. 

  
 38 

	 8.2	Accounts 

  

	8.2.1	General 

 The Borrower
undertakes with each of the Lenders, the Agent, the Account Bank and the Security Trustee that it will: 
  

	 	(a)	on or before the first Drawing open the Accounts with the Account Bank; and 

 

	 	(b)	procure that all moneys payable to the Borrower including, without limitation, in respect of the Earnings of the Vessel (including all hire and early termination fees
payable to it under the Time Charter, all payments made under any letters of credit or insurance policies issued in favour of the Borrower pursuant to the Time Charter and pursuant to the Insurances but excluding any Borrower Priority Payments)
shall, unless and until the Agent directs to the contrary pursuant to the Security Documents be paid to the Revenue Account; 

  

	 8.3	Revenue Account: withdrawals 

 Unless the Agent otherwise agrees in writing (acting on the instructions of the Majority Lenders) the Borrower shall not be entitled to withdraw any moneys from the Revenue Account at any time other than
for the following purposes and in the following order of priority: 
  

	8.3.1	to pay the proper and reasonable operating expenses (including costs of insuring, repairing and maintaining the Vessel) of the Vessel, including amounts properly due to
the Manager under the Management Agreement, the Supervisors under the Supervision Agreement and Mitsui under the Corporate Management Agreement, the proper and reasonable expenses of administering the affairs of the Borrower and the Taxes of the
Borrower; 

  

	8.3.2	 to transfer to the Dry Docking Reserve Account, first time three (3) months after the Delivery Date and at three (3) Monthly intervals
thereafter up to and including the date upon which the Vessel completes each such scheduled dry docking, an amount equal to
1/
20 of the total Dry Docking Reserve Account Payments in respect of such next scheduled dry docking;

  

	8.3.3	to transfer to the Retention Account on the next following Retention Date all or part of the Retention Amount for such Retention Date; 

 

	8.3.4	to pay any other amounts payable under the Security Documents (including payments to the Swap Providers under any of the Swap Agreements and in case of partial payments
the Swap Providers will be paid pro-rata); 

  

	8.3.5	to transfer to the Debt Service Reserve Account all or part of the DSRA Amount if any remains unpaid; and 

 

	8.3.6	to transfer any surplus to the Distribution Account unless at any relevant time a Dividend Restriction Event has occurred which is continuing unremedied or unwaived in
which case any surplus shall be transferred to the Dividend Lock-Up Account, Provided that where such Dividend Restriction Event has ceased to be continuing and in circumstances where there is no Potential Event of Default or Event of Default which
is continuing unremedied or unwaived such surplus may be transferred from the Dividend Lock-Up Account to the Distribution Account. 

  

	 8.4	Dry Docking Reserve Account: withdrawals 

  

	8.4.1	Unless the Agent otherwise agrees in writing, the Borrower shall not be entitled to withdraw any moneys from the Dry Docking Reserve Account other than to meet
dry-docking costs which shall have been advised to and the aggregate amount of which shall have been approved by the Agent (acting reasonably and without delay) and in respect of which the Borrower shall have provided to the Agent reasonably
satisfactory documentary evidence that such dry-docking costs have been incurred or will be incurred provided however that the Borrower shall be entitled to request the Agent by notice in writing to release any balance standing to the credit of the
Dry Docking Reserve Account, after reimbursement to the Borrower from the Dry Docking Reserve Account of all dry docking costs and expenses paid by it, immediately following completion of a scheduled dry docking of the Vessel and the Agent shall
transfer any such balance to the Distribution Account provided that the Agent is satisfied that: 

  
 39 

	 	(a)	all amounts then required to be paid to the Retention Account have been so paid; 

 

	 	(b)	the DSRA Amount has been paid in full and is standing to the credit of the Debt Service Reserve Account or has been replaced by the DSRA Letter of Credit; and

  

	 	(c)	at such time no Dividend Restriction Event has occurred which is continuing unremedied or unwaived in which case any such balance shall be transferred to and retained
in the Dividend Lock-up Account. 

  

	8.5	Debt Service Reserve Account: withdrawals 

 Without prejudice to the rights of the Lender Finance Parties under clause 9.1.18 (particularly, without limitation, the right of the Lender Finance Parties to use the amounts standing to the credit of
the Debt Service Reserve Account to service any Loan repayments which have become due), the Borrower shall not be entitled to withdraw any moneys from the Debt Service Reserve Account at any time from the date of this Agreement and so long as moneys
are owing under the Security Documents save that, unless and until a Potential Event of Default or an Event of Default shall occur (which is continuing unremedied or unwaived) and the Agent shall direct to the contrary in accordance with the
Security Documents, the Borrower may withdraw moneys from the Debt Service Reserve Account provided that a DSRA Letter of Credit is issued in an amount sufficient to constitute security at least of an equivalent Dollar for Dollar value as the amount
withdrawn (and subject to the other provisions of this Agreement in relation to the DSRA Letter of Credit). In the event that the credit rating of an L/C Issuer falls below the Minimum Credit Rating applicable to it as described in clause 9.1.20,
the Borrower shall immediately credit the Debt Service Reserve Account with an amount equal to the amount covered by the DSRA Letter of Credit provided by such L/C Issuer until the conditions set out in clauses 9.1.18 and 9.1.20 have been satisfied
in full, and clause 9.1.18 shall apply as if the reference in such clause to “the date falling twenty seven (27) months after the Delivery Date” were a reference to the date the Borrower so credited the Debt Service Reserve Account
and, to the extent that the Borrower is in breach of its obligations to so credit the Debt Service Reserve Account, the Lender Finance Parties shall immediately be entitled in their absolute discretion to make a demand under the DSRA Letter of
Credit for the full amount in respect of which such DSRA Letter of Credit has issued. 
  

	8.6	Dividend Lock-Up Account: withdrawals 

 The Borrower shall not be entitled to withdraw any moneys from the Dividend Lock-Up Account except if there are no Dividend Restriction Events continuing. 

 

	8.7	Distribution Account: withdrawals 

 The Borrower shall be entitled to withdraw and freely apply all moneys standing to the credit of the Distribution Account from time to time. 

 

	8.8	Retention Account: credits and withdrawals 

  

	8.8.1	Unless and until there shall occur an Event of Default which is continuing unremedied or unwaived (whereupon the provisions of clause 8.12 shall apply and subject to
the Security Documents), all Retention Amounts credited to the Retention Account together with interest from time to time accruing or at any time accrued thereon shall be applied by the Account Bank (and the Borrower undertakes to give an
irrevocable and unconditional instruction to the Account Bank so to apply the same) in the following manner: 

  
 40 

	 	(a)	upon each Repayment Date in or towards payment to (i) the Agent of the instalment then falling due for repayment and the amount of interest then due and
(ii) to the Swap Providers of amounts then falling due under the Swap Agreements (if any). Each such application by the Account Bank shall constitute a payment in or towards satisfaction of the Borrower’s corresponding payment obligations
under this Agreement and the Swap Agreements but shall be strictly without prejudice to the obligations of the Borrower to make any such payment to the extent that the aforesaid application by the Account Bank is insufficient to meet the same; and

  

	 	(b)	following any application by the Account Bank pursuant to sub-clause (a) above, in transfer to the Revenue Account of any moneys standing to the credit of the
Retention Account. 

  

	8.8.2	Unless the Agent otherwise agrees in writing and subject to clause 8.8.1, the Borrower shall not be entitled to withdraw any moneys from the Retention Account at any
time from the date of this Agreement and so long as any moneys are owing under the Security Documents. 

  

	8.9	Application of accounts 

At any time after the Agent has exercised its rights pursuant to clause 10.1, the Agent may, without notice to the Borrower but subject to
the terms of the Security Documents, instruct the Account Banks to apply all moneys then standing to the credit of the Accounts (other than the Distribution Account) (together with interest from time to time accruing or accrued thereon) in payment
to the Security Trustee and the Security Trustee shall apply the same in or towards satisfaction of any sums due to the Agent, the Security Trustee, the KEIC Agent, the Swap Providers and the Lenders under the Security Documents in the manner
specified in the Intercreditor Deed. 
  

	8.10	Interest and surpluses 

  

	8.10.1	Each of the Accounts shall bear interest upon the Account Bank’s standard terms for Dollar deposits in similar amounts and for periods comparable for which such
balances appear to the Account Bank likely to remain on the relevant Account and any interest credited to the Accounts (other than the Distribution Account) shall, unless and until an Event of Default (which is continuing unremedied or unwaived)
shall occur in which case, subject to the Security Documents, the provisions of clause 8.9 shall apply, be paid to the Revenue Account. 

  

	8.11	Charging of accounts 

 The
Accounts (other than the Distribution Account) and all amounts from time to time standing to the credit thereof shall be subject to the security constituted and the rights conferred by the relevant Security Documents. 

 

	8.12	General application of moneys 

 Whilst an Event of Default is continuing unremedied or unwaived the Borrower irrevocably authorises the Agent and the Security Trustee to apply all sums which either of them may receive: 

 

	8.12.1	pursuant to a sale or other disposition of the Vessel or any right, title or interest in the Vessel; or 

 

	8.12.2	by way of payment of any sum in respect of the Insurances, Earnings, or Requisition Compensation; or 

 

	8.12.3	otherwise arising under or in connection with any Security Document, in accordance with the terms of the Intercreditor Deed. 

 

	9	Covenants 

 The Borrower
covenants with the Lender Finance Parties in the following terms. 

  
 41 

	9.1	General 

 The Borrower
undertakes with the Lender Finance Parties that, from the date of this Agreement and so long as any moneys are owing under any of the Security Documents and while all or any part of the Commitments remains outstanding, it will: 

 

	9.1.1	Notice of Default 

  

	 	(a)	promptly inform the Agent in writing of any occurrence of which it becomes aware which might materially and adversely affect the ability of any Security Party, the Time
Charterer, the Builder or the Refund Guarantor to perform its obligations under any of the Relevant Documents to which it is a party and, without limiting the generality of the foregoing, will inform the Agent of any Event of Default or Potential
Event of Default or Mandatory Prepayment Event forthwith upon becoming aware thereof and will from time to time, if so requested by the Agent, confirm to the Agent in writing that, save as otherwise stated in such confirmation, no Event of Default
or Potential Event of Default has occurred and is continuing unremedied or unwaived; 

  

	 	(b)	promptly inform the Agent of any occurrence of which it becomes aware which might materially adversely effect the ability or rights of the Borrower to make any claims
under any of the Refund Guarantee or which might reduce or release any of the obligations of any Refund Guarantor under any of its Refund Guarantee; 

  

	9.1.2	Consents and licences 

obtain or cause to be obtained, maintain in full force and effect and comply in all material respects with the conditions and restrictions
(if any) imposed in, or in connection with, every consent, Authorisation, licence or approval of governmental or public bodies or authorities or courts, the failure of which has or might be likely to have a Material Adverse Effect, and do, or cause
to be done, all other acts and things which may from time to time be necessary under applicable law for the continued due performance of all the obligations of the Security Parties under each of the Security Documents; 

 

	9.1.3	Use of proceeds 

 use the
Loan exclusively for the purpose specified in the Recitals and/or clause 2.3.4; 
  

	9.1.4	Pari passu 

 ensure that
its obligations under this Agreement and the other Security Documents shall, without prejudice to the security intended to be created by the Security Documents, at all times rank at least pari passu with all its other present and future unsecured
and unsubordinated indebtedness with the exception of any obligations which are mandatorily preferred by law and not by contract; 
  

	9.1.5	Financial statements 

prepare financial statements of the Borrower in accordance with GAAP in respect of each financial year and cause the same to be reported
on by its auditors and prepare semi-annual (i.e two (2) sets of accounts to be provided each year) unaudited accounts (without accounting notes) and deliver as many copies of the same and copies of each Sponsor’s annual audited financial
statements as the Agent may reasonably require not later than one hundred and twenty (120) days (in the case of the Borrower’s audited financial statements), sixty (60) days (in the case of semi-annual unaudited accounts) or one
hundred and eighty (180) days (in the case of the Sponsors’ annual audited financial statements), in each case after the end of the financial period to which they relate; 

 

	9.1.6	Information 

 deliver to
the Agent or procure that there is delivered to the Agent: 

  
 42 

	 	(a)	at the time of issue thereof, as many copies as the Agent may reasonably require of written communications made by any Security Party to its shareholders or creditors
generally which may reasonably be considered material in the context of this Agreement (other than copies of reports or other notices, statements, or circulars sent or delivered to the Borrower Shareholders by the Borrower, which shall be sent to
the Security Trustee pursuant to clause 6.2.11 of the Share Charges); 

  

	 	(b)	from time to time as the Agent and/or KEIC may reasonably require: 

  

	 	(i)	such financial or other information concerning any Security Party and its affairs which may reasonably be considered material in the context of this Agreement;

  

	 	(ii)	such information relating to the progress of construction of the Vessel, or otherwise in relation to the construction of the Vessel and performance by the Builder of
its obligations under the Building Contract; and 

  

	 	(iii)	such information in connection with the operation, position and condition of the Vessel; 

 

	 	(c)	at the time of each such communication, copies of all material written communications between the Borrower or any other Security Party and: 

 

	 	(i)	the approved brokers; and 

  

	 	(ii)	the approved protection and indemnity and/or war risks associations; and 

  

	 	(iii)	the approved insurance companies and/or underwriters; 

 which relate directly or indirectly to: 
  

	 	(A)	the Vessel and the obligations of the Borrower or any other Security Party relating to the Insurances including, without limitation, all requisite declarations and
payments of additional premiums or calls and all communication relating to non-payment of premiums or calls and cancellation of any of the Insurances or relating to the imposition of any new or modified condition, warranty, exclusion or
qualification or the material alteration of the Insurances; and 

  

	 	(B)	any credit arrangements made between the Borrower or any other Security Party and any of the persons referred to in clauses 9.5.7(a) to 9.5.7(c) relating wholly or
partly to the effecting or maintenance of the Insurances. 

  

	9.1.7	Vessel Annual Operating Budget 

 prior to the commencement of each budget year, submit to the Agent the annual operating budget of the Vessel for such budget year for approval by the Agent (acting on the instruction of the Majority
Lenders and such approval not to be unreasonably withheld or delayed); 
  

	9.1.8	Obligations under Security Documents 

 duly and punctually perform each of the obligations expressed to be assumed by it under the Security Documents to which it is a party; 

 

	9.1.9	Certificate of Financial Responsibility 

 obtain and maintain a certificate of financial responsibility in relation to the Vessel if it is to call at the United States of America; 

  
 43 

	9.1.10	ISM and ISPS Compliance 

ensure that the relevant Company and any Environmental Affiliate complies in all material respects with the ISM Code and the ISPS Code or
any replacements thereof and in particular (without prejudice to the generality of the foregoing) shall ensure that the Company holds (i) a valid and current Document of Compliance issued pursuant to the ISM Code, (ii) a valid and current
Safety Management Certificate issued in respect of the Vessel pursuant to the ISM Code, and (iii) an ISSC in respect of the Vessel, and the Borrower shall promptly, upon request, supply the Agent with copies of the same; 

 

	9.1.11	Compliance with Applicable Laws 

 comply with all applicable laws to which it may be subject from time to time; 
  

	9.1.12	Further Assurance 

 at its
own expense, promptly take all such action as the Agent may reasonably require for the purpose of perfecting or protecting any Lender Finance Party’s rights with respect to the security created or evidenced (or intended to be created or
evidenced) by the Security Documents; 
  

	9.1.13	“Know your customer” Checks 

 if: 
  

	 	(a)	the introduction of or any change in (or in the interpretation, administration or application of) any law or regulation made after the date of this Agreement;

  

	 	(b)	any change in the status of the Borrower after the date of this Agreement; or 

 

	 	(c)	a proposed assignment or transfer by a Lender of any of its rights and obligations under this Agreement to a party that is not a Lender prior to such assignment or
transfer, 

 obliges the Agent or any Lender (or, in the case of (c) above, any prospective new Lender) to
comply with “know your customer” or similar identification procedures in circumstances where the necessary information is not already available to it, promptly upon the request of the Agent or any Lender supply, or procure the supply of,
such documentation and other evidence as is reasonably requested by the Agent (for itself or on behalf of any Lender) or any Lender for itself (or, in the case of (c) above, on behalf of any prospective new Lender) in order for the Agent or
that Lender (or, in the case of (c) above, any prospective new Lender) to carry out and be satisfied it has complied with all necessary “know your customer” or other similar checks under all applicable laws and regulations pursuant to
the transactions contemplated in the Relevant Documents, Provided that, the obligations set forth in this clause shall not apply to information in respect of Angola LNG, the Angola LNG Project (in any respect), the Time Charterer, the Builder, the
Refund Guarantor or the L/C Issuer unless such information is required by Law; 
  

	 	9.1.14	Management Fees 

 pay all
amounts due to the Manager under the Management Agreement when the same become due and payable; 
  

	 	9.1.15	Time Charters 

 ensure
that: 
  

	 	(a)	the Vessel is constructed pursuant to the Building Contract so that on the Delivery Date the Vessel is accepted by the Time Charterer under the Time Charter;

  

	 	(b)	from the Delivery Date and throughout the Facility Period: 

  
 44 

	 	(i)	subject to clauses 5.8.3 and 5.8.4, the Vessel shall be chartered to the Time Charterer under the Time Charter or (subject to clause 9.2.18) a bareboat charter unless
the Agent, acting on the instruction of all the Lenders (acting reasonably and without delay) otherwise agrees; 

  

	 	(ii)	no amendments are made to (aa) the Time Charter (other than in respect of purely technical and/or operational matters which shall have no material
adverse, financial effect upon the Borrower, no adverse effect upon the security rights of the Agent, the Security Trustee, the KEIC Agent, the Lenders or the Swap Providers, which shall not have the effect of reducing the rate of hire
payable under the Time Charter or amending the dates on which such hire is payable or reducing the period of the contractTime Charter itself and which shall in any event be promptly notified to the Agent) or (bb) to
any letters of credit or insurance policies to be issued under the Time Charter, in each case without the consent of the Agent (such consent not to be unreasonably withheld or delayed); and 

 

	 	(iii)	all licenses, consents and Authorisations necessary to permit the proper and lawful operation of the Vessel pursuant to the Time Charter in any Relevant Jurisdiction to
which the Vessel may be ordered or trade are complied with and ensure that each such licence, consent and Authorisation has been properly and validly obtained; and 

 

	 	(c)	upon the occurrence of any force majeure as set out in the Time Charter or any incident or other occurrence of which it is aware which may reasonably be expected to
become a force majeure upon the giving of notice or lapse of time the Borrower shall forthwith advise the Agent of such force majeure or incident or occurrence which may become a force majeure and keep the Agent up to date in respect of all matters
and/or developments in respect of such force majeure and/or incident and/or occurrence; 

  

	9.1.16	Use of Ancillary Cost Advances 

 procure that each Ancillary Cost Advance and the proceeds thereof are used only for the purpose of paying and discharging Ancillary Costs, reimbursing Ancillary Costs already paid by the Borrower, as
contemplated by clause 2.3.4 and paying the KEIC Insurance Premium and for no other purpose; 
  

	9.1.17	Management 

 ensure that
following Delivery the Vessel is managed throughout the Facility Period by the Manager pursuant to the Management Agreement or such party as may replace the Manager in accordance with clause 9.2.18 and 10.3 of this Agreement; 

 

	9.1.18	DSRA Letter of Credit/Debt Service Reserve Account 

  

	 	(a)	on or before the date falling twenty seven (27) Months after the Delivery Date procure that as a result of either: 

 

	 	(i)	the issue of the DSRA Letter of Credit; and/or 

  

	 	(ii)	sums standing to the credit of the Debt Service Reserve Account, 

 the aggregate of the amounts standing to the credit of the Debt Service Reserve Account and/or the amount of the DSRA Letter of Credit shall, subject to clause (b) below, be equal to or not less than
such amount as the Agent shall determine to be 6 Months’ principal and interest repayments under this Agreement (the “DSRA Amount”) Provided Always that: 

 

	 	(A)	the sum standing to the credit of the Debt Service Reserve Account shall, in accordance with and subject to the provisions of the Security Documents, be freely
available to the Lender Finance Parties (a) upon the acceleration of the Loan after the occurrence of an Event of Default which is continuing unremedied or unwaived and (b) to service any Loan repayments which have become due in the
circumstances set out in clause 9.1.18(b) below; and 

  
 45 

	 	(B)	in relation to any DSRA Letter of Credit the Borrower shall provide the Agent with such evidence as the Agent may reasonably require to satisfy the Agent that such DSRA
Letter of Credit has been duly and validly and correctly issued (including, without limitation, a signing authority authorising the L/C Issuer to provide the DSRA Letter of Credit and a legal opinion from counsel in
the jurisdiction of the L/C Issuer in each case in form and substance satisfactory to the Agent), 

 and
in the event that the Borrower elects to issue the DSRA Letter of Credit the Borrower shall ensure that (A) all sums payable under such DSRA Letter of Credit shall, in accordance with and subject to the provisions of the Security Documents, be
freely available to the Lender Finance Parties (a) upon the acceleration of the Loan after the occurrence of an Event of Default which is continuing, (b) to service any Loan repayments which have become due in the circumstances set out in
clause (b) below and where there are insufficient amounts standing to the credit of the Debt Service Reserve Account to service such Loan repayments and (c) in the circumstances set out in clause 8.5 and (B) any DSRA Letter of Credit
shall be renewed or replaced for a period being not less than 12 Months to such value as may be required to satisfy the provisions of this clause 9.1.18 not later than 30 days prior to the scheduled date of its expiry. If the Borrower fails to so
renew or replace the DSRA Letter of Credit, the Borrower agrees that the Security Trustee shall have the right upon written notice to the Borrower to draw the entire amount available under such DSRA Letter of Credit and deposit such amount in the
Debt Service Reserve Account for application in accordance with the provisions of this Agreement. For the avoidance of doubt, if the Security Trustee shall at any time drawdown the entire amount available under any DSRA Letter of Credit and deposit
the same in the Debt Service Reserve Account, such drawdown and deposit shall be deemed to remedy any Event of Default which shall have arisen as a result of the Borrower’s failure to renew or replace such DSRA Letter of Credit for a period of
not less than 12 Months in accordance with the provisions of this clause 9.1.18; 
  

	 	(b)	Notwithstanding the provisions of clauses 8.5 and 9.1.18(a) above, the Lender Finance Parties shall, in their absolute discretion, be entitled to:

  

	 	(i)	use the sum standing to the credit of the Debt Service Reserve Account from time to time; and/or 

 

	 	(ii)	make a demand under the DSRA Letter of Credit, 

 in each case to satisfy the Borrower’s obligation to pay a Repayment Instalment or Repayment Instalments which have become due and such sums and/or (as the case may be) the DSRA Letter of Credit
shall be freely available to the Lender Finance Parties for these purposes. 
 In the event that the Lender Finance Parties
elect to exercise their rights under this clause 9.1.18(b) the Borrower shall have sixty (60) days to restore the aggregate of the amounts standing to the credit of the Debt Service Reserve Account and/or the amount of the DSRA Letter of Credit
to an amount equal to the DSRA Amount. 
  

	9.1.19	Financial covenants 

provide the Agent at the same time it provides its audited financial statements and unaudited semi-annual accounts in accordance with
clause 9.1.5 with a Compliance Certificate signed by an authorised officer of the Borrower (i) that the average DSCR in respect of the immediately preceding four (4) financial quarters is equal to or above 1:10x, (ii) that the average
DSCR in respect of the immediately preceding two (2) financial quarters is equal to or above 1.06x and (iii) its Leverage Ratio for the immediately preceding four (4) financial quarters does not exceed 4:1. Such Compliance Certificate
shall also attach full details of how the said DSCR and Leverage Ratio was calculated; 

  
 46 

	9.1.20	Minimum Credit Rating 

 in
the event that the credit rating of an L/C Issuer falls below the Minimum Credit Rating applicable to it, then the Borrower shall immediately (a) inform the Agent and (b) credit the Debt Service Reserve Account in accordance with clause
8.5; 
  

	9.1.21	Supervision Agreement 

  

	 	(a)	ensure that throughout the period prior to Delivery of the Vessel the construction of the Vessel is supervised by the Supervisor pursuant to the Supervision Agreement
and will not agree to any material variation of the Supervision Agreement or any sum payable by the Borrower to the Supervisor under the Supervision Agreement; and 

 

	 	(b)	at all times enforce all of its rights under the Supervision Agreement; 

  

	9.1.22	Developments regarding the Angola LNG Project 

 as soon as reasonably practicable but subject to any confidentiality restrictions and limitations in the Time Charter and any other agreements of the Borrower, notify the Agent of any material
developments notified to it by the Time Charterer regarding the Angola LNG Project or the Time Charterer, including, but not limited to, decisions regarding the rollover of the Gas Supply Agreement, the identity of the LNG gas buyers and any force
majeure event under the Gas Supply Agreement, the LNG Agreement, the Time Charter or the Gas Sales and Purchase Agreement, Provided always that (subject to clause 9.1.15) the Borrower shall not have or be deemed to have any obligation under this
Agreement or any Security Documents to request any information from the Time Charterer or any of its members, shareholders, directors, officers, employees or representatives regarding the Angola LNG Project or the Time Charterer; 

 

	9.1.23 	Registration 

 ensure that
the Vessel shall on and from the Delivery Date be registered under the laws of the flag of the Flag State (or the flag of such other state as the Agent may consent to in writing, acting on the instruction of the Majority Lenders and KEIC);

  

	9.1.24 	Project Co-ordination Agreement 

  

	 	1.1.1	Prior to the first Drawing, procure the execution of the Project Co-ordination Agreement in a form and substance acceptable in all respects to KEIC and to the Agent
acting on the instructions of the Majority Lenders. 

  

	9.2 	Negative undertakings 

The Borrower undertakes with the Agent that, from the date of this Agreement and so long as any moneys are owing under the Security
Documents and while all or any part of the Commitments remain outstanding, it will not without the prior written consent of the Agent: 
  

	9.2.1 	Negative pledge 

 permit
any Encumbrance (other than a Permitted Encumbrance) to subsist, arise or be created or extended over all or any part of its present or future undertakings, assets, rights or revenues (including, without limitation to the generality of the
foregoing, over the Vessel, the Time Charter, Earnings, Insurances and/or Accounts) to secure or prefer any present or future indebtedness or other liability or obligation of it or any other person; 

  
 47 

	9.2.2	No merger 

 without the
prior written consent of the Agent acting on the instructions of all Lenders merge or consolidate with any other person unless such merger or consolidation does not result in a Change of Control; 

 

	9.2.3	Disposals 

 Subject to the
rights of the Time Charterer under the Time Charter; 
  

	 	(a)	sell, transfer, abandon, lend or otherwise dispose of or cease to exercise direct control over any part (being either alone or when aggregated with all other disposals
falling to be taken into account pursuant to this clause 9.2.3 material in the opinion of the Agent (acting reasonably and without unreasonable delay) in relation to the combined undertakings, assets, rights and revenues of the Borrower) of its
present or future undertaking, assets, rights or revenues (otherwise than by transfers, sales or disposals for full consideration in the ordinary course of trading or otherwise in accordance with the Depot Spares Sharing Agreement) whether by one or
a series of transactions related or not; or 

  

	 	(b)	sell, transfer, abandon, lease or otherwise dispose of or part with possession of the Vessel other than pursuant to clause 9.6.14 or with the prior written consent of
the Agent acting on the instructions of the Majority Lenders and KEIC; 

  

	9.2.4	Other business 

 undertake
any business other than the ownership, financing (including the refinancing of the Vessel at the Maturity Date), maintenance and operation of the Vessel, the Depot Spare Parts, the chartering of the Vessel for the Time Charterer and making
Authorised Investments as permitted by the Security Documents; 
  

	9.2.5	Acquisitions 

 acquire any
further assets other than Authorised Investments, the Vessel, the Depot Spare Parts and other assets and rights arising under contracts entered into by it in the ordinary course of its business of owning, operating, maintaining and chartering the
Vessel or in refinancing the Vessel at the Maturity Date, provided always that the Loan Outstandings shall be repaid in full from the proceeds of such refinancing of the Vessel at the Maturity Date; 

 

	9.2.6	Other obligations 

 incur
any obligations except for obligations arising under the Relevant Documents to which it is a party or contracts entered into by it in the ordinary course of its business of owning, operating, maintaining and chartering the Vessel; 

 

	9.2.7	Guarantees 

 issue any
guarantees or indemnities or otherwise become directly or contingently liable for the obligations of any person, firm, or corporation except for guarantees or indemnities from time to time required in the ordinary course by any protection and
indemnity or war risks association with which the Vessel is entered, guarantees required to procure the release of the Vessel from any arrest, detention, attachment or levy or guarantees or undertakings required for the salvage of the Vessel and
except pursuant to the Security Documents; 
  

	9.2.8	Loans 

 make any loans or
grant any credit (save for normal trade credit in the ordinary course of business) to any person or agree to do so; 

  
 48 

	9.2.9	No borrowing 

 incur any
Financial Indebtedness or undertake any material capital commitment except: 
  

	 	(a)	for trade credit in the ordinary course of business and Financial Indebtedness pursuant to the Security Documents (including the Swap Agreements); and

  

	 	(b)	the Minimum Borrower Shareholders’ Equity and Additional Shareholders’ Equity contributed by way of subordinated debt and subordinated to the amounts due and
owing to the Agent, the Security Trustee, the KEIC Agent, the Swap Providers and the Lenders under the Security Documents; 

  

	9.2.10	Repayment of borrowings 

repay the principal of, or pay interest on or any other sum in connection with any of its Financial Indebtedness except such Financial
Indebtedness as is permitted by the Security Documents or with the prior written consent of the Agent; 
  

	9.2.11	Sureties 

 permit any
Financial Indebtedness of the Borrower to any person (other than the Lenders and/or the Agent and/or the Security Trustee and/or the Swap Providers under the Swap Agreements to be guaranteed by any person (save for guarantees or indemnities from
time to time required in the ordinary course by any protection and indemnity or war risks association with which the Vessel is entered, guarantees required to procure the release of the Vessel from any arrest, detention, attachment or levy or
guarantees or undertakings required for the salvage of the Vessel; 
  

	9.2.12	Share capital and distribution 

 purchase or otherwise acquire for value any shares of its capital or declare or pay any dividends or distribute any of its present or future assets, undertakings, rights or revenues to any of its
shareholders, save that the Borrower shall be permitted to declare or pay dividends provided that no Event of Default or Dividend Restriction Event has occurred and is continuing unremedied or unwaived or would occur as a result; 

 

	9.2.13	Subsidiaries 

 form or
acquire any Subsidiaries; 
  

	9.2.14	Constitutional documents 

agree to any material change of its memoranda and articles of association or other constitutional documents; 

 

	9.2.15	Project Documents 

subject to clause 9.l.15(b)(ii) (which provides, for the avoidance of doubt, that amendments to the Time Charter in respect of
technical and/or operational matters which shall have no material adverse financial effect upon the Borrower, no adverse effect upon the security rights of the Agent, the Security Trustee, the KEIC Agent, the Lenders or the Swap Providers, which
shall not have the effect of reducing the rate of hire payable under the Time Charter or amending the dates on which such hire is payable or reducing the period of the Time Charter itself and which shall in any event be promptly notified to the
Agent, may be made or permitted by the Borrower without the consent of the Ageent), materially amend, modify or waive any provision of the Project Documents to which it is a party or agree to materially amend, modify or waive any provision of
the Project Documents to which it is not a party but which requires its consent without the prior written consent of the Agent (acting on the instructions of the Majority Lenders); 

  
 49 

	9.2.16	Borrower’s other documents 

 enter in to any other material documents or agreements relating to the Angola LNG Project (other than such documents or agreements contemplated by the Time Charter) (such other material documents or
agreements, “Borrower’s Other Documents”) and, if the Agent shall consent to the Borrower’s entry into any Borrower’s Other Documents (which consent shall not be unreasonably withheld or delayed but the giving of
which consent may be subject to the Borrower assigning or otherwise charging all its rights, title, benefits and interests under such Borrower’s Other Documents in favour of the Security Trustee as security for the Loan and any other sums
payable under the other Security Documents), the Borrower shall not agree to any material change to the Borrower’s Other Documents without the prior written consent of the Agent (which consent shall not be unreasonably withheld or delayed);

  

	9.2.17	Ownership of Borrower 

permit any change in the shareholders or their respective (direct or indirect) shareholdings in the Borrower as at the date hereof being:

  

	 	(i)	Mitsui—34%; 

  

	 	(ii)	NYK—33%; and 

  

	 	(iii)	Teekay 33%. 

 Provided however
that (a) on Delivery, Teekay or its Wholly-Owned Subsidiary shallmay, subject to the Agent having confirmed to Teekay in writing (not to be unreasonably delayed) that it is satisfied, acting reasonably that no material
adverse effect on Teekay LNG’s consolidated financial position or Teekay LNG’s ability to comply with its material obligations under any of the Security Documents has occurred and is continuing with respect to Teekay LNG, transfer all of
its shares in the Borrower to Teekay LNG or its Wholly-Owned Subsidiary and Teekay LNG or its Wholly-Owned Subsidiary (as applicable) shall become a “Borrower Shareholder” in place of Teekay or its Wholly-Owned Subsidiary;
(b) any of the Borrower Shareholders may at any time but subject always to the requirements of paragraph (c) below, transfer all or part of its shareholding in the Borrower to:- 

 

	 	(aa)	a Qualifying Entity, provided that such Qualifying Entity accedes to the Security Documents as a Sponsor and a Borrower Shareholder in respect of its proportionate
interest in the Borrower; 

  

	 	(bb)	a Wholly-Owned Subsidiary of any Qualifying Entity provided that, (a) such Wholly-Owned Subsidiary accedes to the Security Documents as a Borrower Shareholder in
respect of its proportionate ownership interest in the Borrower, and (b) the Qualifying Entity accedes to the Security Documents as a Sponsor in respect of its proportionate indirect ownership interest in the Borrower; 

 

	 	(cc)	a Sponsor, another Borrower Shareholder or to an Affiliate of a Sponsor or a Borrower Shareholder, provided that, such Affiliate or Sponsor (as the case maybe) accedes
to the Security Documents as a Borrower Shareholder in respect of its proportionate ownership interest in the Borrower; or 

  

	 	(dd)	any other person approved by the Agent acting on the instructions of all of the Lenders, provided that such approved person accedes to the Security Documents as a
Sponsor and/or Borrower Shareholder (as applicable) in respect of its proportionate direct or indirect ownership interest in the Borrower; 

 PROVIDED THAT 
  

	 	(ee)	 in each case, in order to satisfy the requirement to accede to the Security Documents and as a condition precedent to the transfer of any shares to
such party, such Qualifying Entity, Affiliate or other approved person, as the case maybe, shall in each case, have first entered into such documents including where it becomes a Borrower Shareholder, a share charge in favour of the Security Trustee
in the same form as the Share PledgesCharges and in each case in form and substance satisfactory to the Agent and as shall deem necessary provide the Agent with such evidence including corporate authorities and such legal
opinions as the Agent shall require in order for the Agent to be satisfied that such party has acceded to the Security Documents as a Borrower Shareholder and/or Sponsor as the case maybe; and

  
 50 

 (c) provided that at all times during the Facility Period one or more of Mitsui, NYK, Teekay
or (following any transfer permitted and as referred to in (a) above) Teekay LNG or its Wholly-Owned Subsidiary shall directly or indirectly maintain a shareholding in the Borrower of an amount in aggregate which shall not be less than sixty
six per cent (66%) of the full issued and outstanding share capital of the Borrower from time to time; and 
  

	9.2.18	Replacement of Manager 

without the prior written consent of the Agent (acting on the instructions of the Majority Lenders) and KEIC replace the Manager, provided
that (a) the Agent’s consent shall not be required if the Manager is replaced by Teekay Shipping Limited (or one of its Affiliates) pursuant to clauses 16.2.4 or 16.6 of the Time Charter and (b) the Agent’s consent shall not be
unreasonably withheld or delayed where the Time Charterer has exercised its option pursuant to clause 29.6 of the Time Charter to convert the Time Charter into a bareboat charter of the Vessel; 

 

	9.3	Pre-delivery positive undertakings 

 The Borrower, hereby undertakes and agrees with each of the Lender Finance Parties that from the date of this Agreement until the Delivery Date or, if earlier, the date upon which no moneys are owing
under the Security Documents and no Commitments remain outstanding, that it will: 
  

	9.3.1	Document of title to the Vessel 

 give irrevocable instructions to the Builder that at any time upon which title to the Vessel shall be or become transferable and be capable of transfer to hold the Vessel and the Builder’s
Certificates and any other document of title to the Vessel to the order and at the disposal of the Security Trustee and use its best endeavours to ensure that the Builder complies with such instructions; 

 

	9.3.2	Performance of the Building Contracts 

 duly and punctually observe and perform all the conditions and obligations imposed on it by the Building Contract; 
  

	9.3.3	Performance by Builder 

exercise best endeavours to ensure that the Builder observes and performs all conditions and obligations imposed on it by the Building
Contract and take all steps within its power to ensure that the Builder proceeds with the construction of the Vessel with due diligence and despatch in accordance with the Building Contract; 

 

	9.3.4	Arbitration under the Building Contract 

 in the event that the Builder and/or the Borrower resort to arbitration as provided in Article XXVII of the Building Contract, immediately notify the Agent in writing that such arbitration has been
initiated, advise the Agent in writing of the identity of the appointed arbitrators and upon termination of the arbitration notify the Agent in writing to that effect and supply the Agent with a copy of the arbitration award and a certified English
translation thereof (if the award is not in English); 

  
 51 

	9.3.5	Conveyance on default 

where the Vessel is (or is to be) sold in exercise of any power contained in the Security Documents or otherwise conferred on the Security
Trustee, to execute, forthwith upon request by the Agent, such form of conveyance of the Vessel as the Agent may require; 
  

	9.3.6	Enforcement of Borrower’s rights 

 do or permit to be done each and every act or thing which the Agent and/or the Security Trustee may from time to time require to be done in accordance with the terms of the Security Documents for the
purpose of enforcing the Borrower’s rights (which the Borrower have failed to enforce or to enforce in a manner reasonably satisfactory to the Security Trustee) under or pursuant to the Building Contract; 

 

	9.3.7	Notification of rejection of Vessel 

 notify the Agent and the Security Trustee immediately if the Builder exercises, or purports to exercise or gives notice (written or oral) of its intention to exercise any right to cancel, rescind,
repudiate or otherwise terminate the Building Contract or to render a performance materially different from that which the Building Contract obliges it to render or (with the prior written consent of the Agent given pursuant to clause 9.4.6) the
Borrower cancels, rescinds, repudiates or otherwise terminates the Building Contract or purports to do so or (with the prior written consent of the Agent given pursuant to clause 9.4.6) the Borrower rejects the Vessel or purports to do so or if the
Vessel shall become a Total Loss or partial loss or shall be damaged in a manner affecting its Classification or the Refund Guarantor cancels, rescinds, repudiates or otherwise terminates the Refund Guarantee or purports to do so; 

 

	9.3.8	Vessel name and registration 

 register the Vessel under the laws and flag of the Flag State immediately upon its Delivery and keep the Vessel so registered at all times from the Delivery Date in accordance with clause 9.1.23;

  

	9.3.9	Non-compliance with Time Charter 

 provide the Agent with full details of any matter relating to the construction of the Vessel which could result in the Vessel not being in compliance with the Time Charter within 30 days of such matter
coming to the attention of or being brought to the attention of the Borrower; 
  

	9.3.10	Delays 

 provide the Agent
with full details regarding any delays which arise or may arise with respect to the Scheduled Delivery Date of the Vessel under the Building Contract promptly upon such delays or possible delays coming to the attention of or being brought to the
attention of the Borrower; and 
  

	9.3.11	Mortgage 

 execute, and
procure the registration of, the Mortgage under the laws and flag of the Flag State and the Deed of Covenant immediately upon the Delivery. 
  

	9.4	Pre-delivery negative undertakings 

 The Borrower, hereby further undertakes and agrees with each of the Lender Finance Parties that from the date of this Agreement until the Delivery Date or, if earlier, the date upon which no moneys are
owing under the Security Documents and no Commitments remain outstanding, it will not without the prior written consent of the Agent (and then only subject to such conditions as the Agent may impose) acting on the instructions of the Majority
Lenders and KEIC: 

  
 52 

	9.4.1	Sale or other disposal 

sell or agree to sell, transfer, abandon or otherwise dispose of the Vessel or any share or interest therein; 

 

	9.4.2	Creation of Encumbrances 

create or agree to create or permit to exist any Encumbrance over the Vessel (or any share or interest therein) or over the Building
Contract, the Guarantee Bond or the Refund Guarantee other than the Encumbrances created or to be created pursuant to or as contemplated by the Security Documents and Permitted Encumbrances; 

 

	9.4.3	Variation of Contracts 

agree to any variation of the Building Contract or any substantial variation of the specification of the Vessel (and for the purpose of
this paragraph any extras, additions or alterations which the Borrower may desire to effect in the building of the Vessel shall be deemed to constitute a substantial variation of the specification of the Vessel if the cost thereof (which shall in
every case be agreed in writing between the Borrower and the Builder before the work in respect of such variation is put in hand irrespective of whether the prior consent thereto of the Agent be required hereunder) or if the cost of the modification
causes or will cause the Total Project Cost (estimated by the Borrower as of such date and notified to the Agent) to exceed one hundred and ten per cent. (110%) of the Scheduled Vessel Project Cost, Provided always that the Agent shall not
unreasonably withhold or delay its consent if the Borrower shall evidence to the Agent that the Borrower is in a position to fund any sums from shareholders funds without prejudicing the Borrower’s ability to complete the construction and
delivery of the Vessel in accordance with the Building Contract Provided further that, nothing in this clause 9.4.3 shall prohibit the Borrower from varying the specification of the Vessel to the extent the Borrower has an obligation to make such
variation of the Vessel pursuant to clause 5.1 of the Time Charter or if such variation is required by applicable Law or the Classification Society. If the Borrower has an obligation to make such variation to the Vessel pursuant to clause 5.1 of the
Time Charter, the Borrower shall notify the Agent in writing of such variation and shall provide the Agent, from time to time at the Agent’s reasonable request, information regarding the variation; 

 

	9.4.4	Releases and waivers of Building Contract 

 release the Builder from any of its obligations under the Building Contract or waive any breach of the Builder’s obligations thereunder or consent to any such act or omission of the Builder as would
otherwise constitute such breach; 
  

	9.4.5	Delays 

 without prejudice
to clause 9.4.3, agree to any variation of the Building Contract or the specification of the Vessel which would delay the time for delivery of the Vessel and be likely in the opinion of the Agent (acting reasonably) to put at risk the acceptance of
the Vessel by the Time Charterer under the Time Charter unless the prior written consent to such variation given in writing by the Time Charterer shall have been provided to the Agent; 

 

	9.4.6	Rejection and cancellation 

either exercise or fail to exercise any right which the Borrower may have to reject the Vessel or cancel or rescind or otherwise terminate
the Building Contract Provided always that any such rejection of the Vessel or cancellation, rescission or other termination of the Building Contract by the Borrower after such consent is given shall be without responsibility on the part of the
Agent which shall be under no liability whatsoever to the extent that such rejection, rescission, cancellation or termination is thereafter adjudged to constitute a repudiation or other breach of the Building Contract by the Borrower Provided always
that if the Agent shall not respond (whether in the positive or the negative) within 30 days of any request for such consent being made the Agent shall be deemed to have consented to such request; 

  
 53 

	9.4.7	Assignment of Earnings 

assign or agree to assign otherwise than to the Security Trustee the Earnings or any part thereof; 

 

	9.4.8	Variation of and demands under the Refund Guarantee 

 agree to any variation of the Refund Guarantee nor make any demand for payment under the Refund Guarantee; 
  

	9.4.9	Release and waiver of Refund Guarantee 

 release the Refund Guarantor from any of its obligations under the Refund Guarantee or waive any breach of the Refund Guarantor’s obligations thereunder or consent to any such act or omission of the
Refund Guarantor as would otherwise constitute such breach; and 
  

	9.4.10	Chartering 

 except
pursuant to the Time Charter, let or agree to let the Vessel on demise charter for any period, or by any time or consecutive voyage charter. 
  

	9.5	Insurances 

  

	9.5.1	The Borrower covenants to ensure and procure at its own expense (and for the avoidance of doubt at no cost and expense to the Lender Finance Parties) that the following
provisions of this clause 9.5 are complied with at all times during the Facility Period in respect of the Vessel. The Borrower confirms that throughout the Facility Period, the Vessel shall be in every respect at the risk of the Borrower.

  

	9.5.2	Maintenance of Insurances 

The Vessel shall be kept insured at no cost to the Lender Finance Parties against: 

 

	 	(a)	fire and usual marine risks (including excess risks) and war risks (including terrorism, sabotage, vandalism, malicious mischief, blocking and trapping);

  

	 	(b)	protection and indemnity risks (including pollution risks) and excess war protection and indemnity risks, on “full entry” terms; 

 

	 	(c)	in respect of such other matters of whatsoever nature and howsoever arising in respect of which insurance would be maintained by a prudent owner or operator of vessels
of a similar age, condition and type as the Vessel; and 

  

	 	(d)	loss of hire. for a minimum cover period of (i) one hundred and eighty (180) days, with a maximum deductible of fourteen
(14) days or (ii) following receipt of a written request from the Agent, such longer period as_ may from time to time be reasonably and commercially available in the insurance market for vessels of similar age, size and type as the Vessel, and
for a rate of hire at least equal to the rate set out in the Time Charter. 

  

	9.5.3	Terms of Insurances 

 Such
Insurances shall be effected: 
  

	 	(a)	in Dollars or such other currency as the Agent and the Borrower may agree; 

 

	 	(b)	in the case of fire and usual marine risks and war risks (on an agreed value basis) in an amount equal to the Insured Loss Value applicable on the first day of the
period for which the insurances are renewed; 

  
 54 

	 	(c)	in the case of protection and indemnity risks (including pollution liability risks), in an amount equal to the highest amount in respect of which cover is in accordance
with customary insurance market practice taken out by prudent owners or operators of vessels of a similar type, size, age, condition and flag as the Vessel with protection and indemnity risks associations that are members of the International Group
of Protection and Indemnity Associations (but in the case of pollution risks, for a minimum amount of one billion Dollars ($1,000,000,000) or where cover for such risks is not available in such an amount, such lesser amount as is the best level of
cover available in the market at the applicable time, having regard to the cover being taken out by prudent owners or operators of similar vessels to the Vessel; 

 

	 	(d)	in the case of loss of hire insurances in such amounts and upon such terms as shall from time to time be approved in writing by the Agent; 

 

	 	(e)	on terms approved under clause 9.5.18, but subject to a minimum requirement of the scope of coverage of that provided by the Institute Time Clauses and Additional
Perils Clause with their War and Strikes sister clauses extended as necessary or as provided by the equivalent full conditions forms of other nationality (so far as can be reasonably obtained in the market at the applicable time); and

  

	 	(f)	through brokers and with insurance companies and/or underwriters or, in the case of war risks and protection and indemnity risks, in war risks and protection and
indemnity risks associations, in each case approved under clause 9.5.18. 

  

	9.5.4	Further protection for Agent 

 In addition to the terms set out in clause 9.5.3, the Insurances effected under such clause shall: 
  

	 	(a)	in the case of the Insurances in respect of marine risks and war risks, be endorsed by way of a loss payable clause to the effect that: 

 

	 	(i)	payment of a claim for a Total Loss will be made to the Security Trustee (and shall, be applied in accordance with the relevant provisionsclause
6 of the Intercreditor Deed); and 

  

	 	(ii)	payment of a claim for an amount which equals or exceeds the Threshold Amountten million Dollars($ 10,000,000) shall be paid to the Security
Trustee and shall be applied in accordance with the relevant provisions of the lnter creditor Deed; andas follows: 

  

	 	(A)	Subject to (aa) there being no Event of Default (other than an Event of Default under clause 10.2.1 (Failure to Pay) which has occurred due to the Vessel being
off-hire in order for the necessary repair work to be completed) and (bb) clause 9.5.4(a)(v) below, in the event that the Borrower (or the Sponsors on behalf of the Borrower) have instructed a shipyard to commence the repair works, which shipyard
and repair works are acceptable to the Security Trustee acting reasonably and promptly (and, to the extent that the shipyard and repair works have been approved or nominated by the Time Charterer, such shipyard and repair works shall be deemed to be
acceptable to the Security Trustee for these purposes), and paid for the repairs (such payments to be duly evidenced), to the Borrower (or, as the case may be, the Sponsors) upon resumption of the Vessel into service under the Time Charter, to
reimburse the Borrower (or, as the case may be, the Sponsors) for the amounts so paid: or 

  
 55 

	 	(B)	Subject to (aa) there being no Event of Default (other than an Event of Default under clause 10.2.1 (Failure to Pay) which has occurred due to the Vessel being
off-hire in order for the necessary repair work to be completed) and (bb) clause 9.5.4(a)(v) below, in the event that the Time Charterer has instructed a shipyard to commence the repair works, which shipyard and repair works are acceptable to the
security Trustee acting reasonably and promptly (and, to the extent that the shipyard and repair works have been approved or nominated by the Time Charterer, such shipyard and repair works shall be deemed to be acceptable to the Security Trustee for
these purposes), and paid for part or the whole of the repairs and in respect of which the Borrower is required to reimburse the Time Charterer pursuant to paragraph 2.3 of schedule XI to the Time Charter to the Time charterer to reimburse the Time
Charterer for the amounts so paid (and in satisfaction of the Borrower’s obligation to reimburse the Time Charterer pursuant to clause 2.3 of Schedule XI to the Time Charter), with the balance to be paid to the relevant shipyard conducting such
repairs (in or towards payment of any repairs in respect, of which payment is outstanding) PROVIDED THAT, where such repairs will require the Vessel to remain off-hire for more than 120 days, the Security Trustee has received prior written
confirmation from the Time Charterer that the Time Charterer will not exercise its rights under clause 22.4 of the Time Charter in respect of such off-hire period; and 

 

	 	(C)	if neither the Borrower (nor the Sponsors on behalf of the Borrower) nor the Time Charterer have instructed a shipyard and paid for the repairs (or, in the case of
the Time Charterer, part thereof) as described in clauses 9.5.4(a)(ii)(A) or 9.5.4(a)(ii)(B) above, or the conditions, attached to the payment of the amounts to the Borrower, Sponsors or, as the case may be, Time Charterer (being, in the case of the
Borrower, the requirement that that Vessel has resumed service under the Time Charter and, in the case of the Time Charterer, the requirement that where such repairs will require the Vessel to remain off-hire for more than 120 days, the Security
Trustee has received prior written confirmation from the Time Charterer that the Time Charterer will not exercise its rights under clause 22.4 of of the Time Charter in respect of such off-hire period) are not satisfied within forty five
(45) days of the completion of the repair works, Security Trustee shall, acting upon the insrtruction of the Majority Lenders, have the option to either (a) apply such amounts in repairing the damage or (b) apply such amounts in
accordance with clause 6 of the Intercreditor Deed; and 

  

	 	(iii)	Subject to no Event of Default having occurred which is continuing unremedied and unwaived, payment of a claim for an amount which is less than ten million Dollars
($10,000,000) shall be made to the Borrower who shall apply the same (a) in or toward making good the loss and fully repairing all damage in respect whereof such payment shall have been made or (b) to the Time Charterer to reimburse the
Time Charterer for amounts paid by the Time Charterer in relation to the repair of the Veessel pursuant to paragraph 2.3 of Schedule XI to the Time Charter: and 

 

	 	(iv)	where there is any surplus after the Insurance proceeds have been applied pursuant to this clause 9.5.4(a) in respect of the relevant repairs, such surplus Insurance
proceeds shall be paid to the Security Trustee for application in accordance with clause 6 of the Intercreditor Deed); and 

  

	 	(v)	the application of clause 9.5.4(a)(ii) above is the subject to the Borrower being in compliance with its obligation to maintain loss, of hire insurance in accordance
with clause 9.5.2.(d); and 

  

	 	(vi)	(iii) as long as no Event of Default has occurred and is continuing unremedied or unwaived, payment of any other claim shall be made to the Borrower or, as
applicable, such other Security Party, who shall apply the same in or towards making good the loss and fully repairing all damage in respect whereof such payment shall have been made and after the occurrence of an Event of Default and whilst
itif an Event of Default (other than an Event Default under clause 10.2.1 (Failure to Pay) which has occurred due to the Vessel being off-hire in order for the necessary repair work to be completed), has occurred and is continuing
unremedied or unwaived, and following notification by the Security Trustee to the approved brokers, payment of any such claim shall be made to the Security Trustee, and shall be applied in accordance with the relevant
provisionsclause 6 of the Intercreditor Deed; 

  
 56 

	 	(b)	in the case of the Insurances in respect of protection and indemnity risks, be endorsed by way of a loss payable clause to the effect that moneys payable thereunder
shall be paid in reimbursement of the assured which has settled the liability to which the relevant claim relates or, if so agreed by the relevant insurers, be paid directly to the person to whom was incurred the liability in respect of which the
relevant money was paid unless and until the Security Trustee, following the occurrence of an Event of Default which is continuing unremedied or unwaived, shall direct that they shall be paid to the Security Trustee whereupon they shall be paid to
the Security Trustee and shall be applied in accordance with the relevant provisionsclause 6 of the Intercreditor Deed; 

  

	 	(c)	in the case of Insurances in respect of loss of hire be endorsed by way of a loss payable clause to the effect that all moneys payable thereunder shall, be paid to the
Borrower, unless and until the Security Trustee, following the occurrence of an Event of Default which is continuing unremedied or unwaived, shall direct that these shall be paid to the Security Trustee whereupon they shall be paid to the Security
Trustee and shall be applied in accordance with the relevant provisionsclause 6 of the Intercreditor Deed. 

  

	9.5.5	Renewals 

  

	 	(a)	As soon as possible, but in any case not less than fourteen (14) days before the expiry of any of the policies, entries or contracts forming part of the Insurances
or if there is a change in the insurers and/or markets through whom the Insurances are placed, the Borrower shall notify the Agent of the names of the brokers (or other insurers) and any protection and indemnity and/or war risks association through
or with whom such Insurances are proposed to be renewed and (if any material change is proposed) of the proposed terms and amounts of renewal. The Borrower shall also promptly notify the Agent of any material change in the information notified to
the Agent pursuant to this clause 9.5.5 and shall provide the Agent with particulars of such changes. If at any time the terms and amounts on and for which the Insurances are proposed to be renewed or the identity of the broker or war or protection
and indemnity risks associations with whom the Insurances are proposed to be renewed are not approved by the Agent, as contemplated by clause 9.5.18, the Agent shall notify the Borrower promptly in writing of the withdrawal of its approval, and the
Borrower shall procure that the Insurances are renewed or replaced on terms satisfactory to the Agent (acting reasonably); 

  

	 	(b)	Before the expiry of any Insurances the Borrower shall procure that such relevant Insurances are renewed and shall confirm to the Agent that such renewals have been
effected or shall procure that such confirmation is given to the Agent before the expiry of any such Insurances; and 

  

	 	(c)	Promptly after each such renewal, the Borrower shall procure that the Agent is provided with the details of the terms and conditions and amounts on which and for which
such Insurances have been renewed. 

  

	 	(d)	If, after renewal and after review by the Agent of the terms and conditions of renewal, the Agent advises the Borrower that the terms and conditions of such Insurances
as renewed, do not conform with the requirements of this clause 9.5.5 (which advice shall specify in reasonable detail the particular discrepancies) then, after consultation with the Agent, the Borrower shall ensure that any such discrepancies are
corrected promptly. 

  
 57 

	9.5.6	Custody of Policy Documents/Loss Payable Clauses 

 The Borrower shall procure that there shall be deposited with the brokers and/or insurers through which the Insurances are arranged from time to time copies of all slips, cover notes, policies
certificates of entry or other instruments of insurance from time to time issued in connection with such of the Insurances referred to in this clause 9.5.6 as are effected through such brokers and/or the war risks and protection and indemnity
association approved in accordance with clause 9.5.18 and shall also procure that, in the case of the Insurances referred to in clause 9.5.2(a), the relevant loss payable clause shall be incorporated on the relevant cover note or policy and, in the
case of the protection and indemnity Insurances referred to in clause 9.5.2(b), the relevant loss payable clause shall be incorporated on the relevant certificate of entry or policy, and the Borrower shall procure that the Agent shall be furnished
with certified copies of the relevant cover note or policy or certificate of entry or policy, duly endorsed. 
  

	9.5.7	Letters of undertaking 

In relation to all Insurances effected from time to time under and in accordance with this clause 9.5.7, the Borrower shall ensure that
all brokers and/or insurers and any protection and indemnity or war risks associations in which the Vessel is entered, in each case being approved under clause 9.5.18, provide the Agent with letters of undertaking: 

 

	 	(a)	in the case of an approved broker in the form of the L.I.B.C. Recommended Brokers’ Letter of Undertaking of October 1984 or, if such form no longer represents the
then current market practice in the insurance market in which the approved broker operates, in such form as the Agent and the Borrower shall agree, having regard to the then current market practice in the insurance market in which the approved
broker operates, and any professional association of which that approved broker is a member; and 

  

	 	(b)	in the case of a protection and indemnity association, having regard to the current market practice and the practices prescribed by the International Group of
Protection and Indemnity Associations or, if the relevant protection and indemnity association is not a member of the International Group of Protection and Indemnity Associations but has otherwise been approved by the Agent in accordance with clause
9.5.18, the current practice of that association (and which will for all purposes provide for notification to the Agent prior to the cancellation of any such entry); and 

 

	 	(c)	in the case of a war risks association, having regard to the current market practice in the insurance market in which such association operates.

  

	9.5.8	Fleet Cover 

 If any of
the Insurances referred to in clauses 9.5.2(a) and/or 9.5.2(b) form part of a fleet cover, the Borrower will procure that (a) any letter of undertaking referred to in clause 9.5.7 is amended to provide that the relevant brokers shall undertake
to the Lender Finance Parties that they shall neither set-off against any claims in respect of the Vessel any premiums due in respect of other vessels under such fleet cover or any premiums due for other insurances, nor cancel the insurance for
reason of non-payment of premiums for other vessels under such fleet cover or of premiums for such other insurance or (b) that the applicable policy documents are endorsed to the effect that the applicable insurers shall neither set-off against
any claims in respect of the Vessel any premiums due in respect of other vessels under such fleet cover or any premiums due for other insurances, nor cancel the insurance for reason of non-payment of premiums for other vessels under such fleet cover
or of premiums for such other insurance or (c) that the Lender Finance Parties receive other comfort that this will not occur or arranges separate policies for the Vessel. 

 

	9.5.9	No material adverse alteration 

 The Borrower shall comply with the terms and conditions of the Insurances and shall not do and shall ensure that there is no act or omission which would give rise to a right to cancel any Insurances or
render any Insurances, or any policy or policies or certificate or certificates of entry invalid, void, or unenforceable or render any sum paid out under any policy or policies or certificate or certificates of entry or the Insurances evidenced
thereby repayable in whole or in part. The Borrower will not make, and shall procure that there is not made, any material alteration to the terms of any of the Insurances without the prior written consent of the Agent. 

  
 58 

	9.5.10	Operation outside terms of Insurances 

 The Borrower will take all steps necessary so that: 
  

	 	(a)	the Vessel is not operated in any way inconsistent with the provisions or warranties of or implied in, or in contravention of the cover provided by, any Insurance taken
out in accordance with this clause 9.5; 

  

	 	(b)	the Vessel is not engaged in any voyage or to carry any cargo not permitted by any Insurance, in each case without first obtaining the consent (if necessary) of the
insurers to such operation or engagement and complying with such requirements as to extra premium or otherwise as the insurers may prescribe; or 

  

	 	(c)	all requisite certificates of financial responsibility and/or other consents, licences, approvals or Authorisations as may from time to time be required are obtained
and maintained if the Vessel is likely to be operating in or into or off-shore from the United States of America. 

  

	9.5.11	Payment of premiums and calls 

 The Borrower shall procure that (taking account of any applicable grace period) all premiums, calls, contributions or other sums of money from time to time due in respect of any Insurance are paid
punctually and in full. 
  

	9.5.12	Notification of Total Loss 

The Borrower shall procure that the Agent is notified of: 
  

	 	(a)	the levy of any distress on the Vessel or its arrest, detention, seizure, condemnation as prize, Compulsory Acquisition or requisition for title or use; and

  

	 	(b)	(save in the case of Compulsory Acquisition or requisition for title or use or any capture, seizure, arrest, detention or confiscation of the Vessel by any government,
or by persons acting or purporting to act on behalf of any government) any accident, casualty or other event which has caused or resulted in or is likely to cause or result in the Vessel being or becoming a Total Loss. 

 

	9.5.13	Settlement of claims 

  

	 	(a)	The Borrower shall do all things necessary and provide all documents, evidence and information to enable the Lender Finance Parties to collect or recover any moneys
which at any time become due and payable to the Lender Finance Parties or otherwise in respect of the Insurances. 

  

	 	(b)	Subject to the Borrower having provided any necessary security in a timely manner so as to prevent the actual or continued arrest of the Vessel and provided that no
Event of Default shall have occurred and be continuing, the Agent agrees that the Borrower shall have the right to settle, compromise or abandon any claim under the Insurances for Total Loss or in respect of claims in excess of the Threshold Amount
or to give notice of abandonment of the Vessel to the insurers and/or to claim a constructive Total Loss upon the prior written approval of the Agent (such approval not to be unreasonably withheld or delayed, the Borrower acknowledging (without
limitation) that it shall be reasonable for the Agent to withhold its consent if required to do so pursuant to the Relevant Documents or any of them) but that the Agent itself shall not settle, compromise or abandon any such claim without reference
to the Borrower prior to the occurrence of any Event of Default. After the occurrence of any Event of Default while it is continuing unremedied or unwaived, the Security Trustee alone shall have the right to settle, compromise or abandon any claims
under the Insurances and/or give notice of abandonment of the Vessel to the insurers and/or claim a constructive Total Loss. 

  
 59 

	9.5.14	P & I guarantees 

 The
Borrower shall arrange for the execution and delivery of all guarantees and indemnities as may from time to time be required by the Vessel’s protection and indemnity or war risks association. 

 

	9.5.15	Additional Insurance 

Nothing in this clause 9.5.15 shall prohibit the Borrower from placing additional insurance on the Vessel at its own expense and for its
sole benefit provided however that: 
  

	 	(a)	such insurance shall not prejudice the Insurances or recovery thereunder or exceed the amount permitted by warranties or other conditions contained in the Insurances
without the written consent of the insurers of the Insurances; 

  

	 	(b)	where the written consent of the insurers as referred to in clause 9.5.15(a) is required, the Borrower shall procure that there shall be immediately furnished to the
Agent a copy of such consent and, in all cases, with particulars of any additional insurance effected including copies of any cover notes or policies and of the written consent of the insurers of the required insurance in any case where such consent
is necessary; and 

  

	 	(c)	any insurance payments received by the Agent arising solely from additional insurance effected by the Borrower under this clause 9.5.15(a) less amounts due (if any) by
the Agent in respect of Taxes in relation to the sums received shall be paid by the Agent to the Borrower promptly after receipt thereof. 

  

	9.5.16	No Security Interest 

 The
Borrower shall not, and shall procure that no Security Party will, create or permit to exist any security interest over or in respect of the Insurances save for the approved brokers’ or insurers’ right of set off and lien for unpaid
premiums to the extent permitted by clause 9.5.8 and the Encumbrances created by the Assignment. 
  

	9.5.17	Insurance reports and provision of information 

  

	 	(a)	The Borrower shall procure that there shall be provided promptly any information reasonably required for the purpose of the Agent obtaining or preparing any report from
a reputable international independent marine insurance broker or adviser appointed by the Agent as to the adequacy of the Insurances effected or proposed to be effected, and the Borrower shall, promptly upon demand, indemnify the Agent in respect of
reasonable fees incurred by or for the account of the Agent in connection with one such report prepared immediately prior to the Delivery Date and at annual intervals thereafter, but in the case of each annual report only following either any
material change to the terms of any of the Insurances or a change in the identity of the approved brokers, the approved protection and indemnity and/or war risks association or the approved insurance companies and/or underwriters.

  

	 	(b)	The Borrower shall also, on the Agent’s request (not more frequently than annually and, in case of a policy period of more than 12 Months, not more than once in
each policy period), provide to the Agent and the Security Trustee certified copies of all policy documents and certificates of entry relating to the Insurances which are in the possession of the Borrower, its agents or managers or the approved
brokers. 

  

	9.5.18	Approval process 

 The
Agent’s written approval acting on the instructions of the Majority Lenders and KEIC’s written approval must be obtained in relation to the initial placement of Insurances, particularly with respect to requirements as to amounts and terms
of insurance and identity of brokers and the identity and credit standing of the insurers. The Agent’s written approval acting on the instructions of the Majority Lenders and KEIC’s written approval must also be obtained in relation to any
material changes to the amounts and terms of insurance or the identity of the brokers or the identity and credit standing of the insurers on renewal. The Agent will act promptly and will not act unreasonably in relation to giving its approval in
relation to these matters. 

  
 60 

	9.5.19	Mortgagee’s interest insurance/Mortgagee’s additional perils insurance 

Nothing contained in this clause 9.5 shall affect the Security Trustee’s rights to take out mortgagee’s interest insurance,
mortgagee’s additional perils insurance and/or contingent liability insurance in relation to the insurances of the Vessel for its own account save that mortgagee’s interest insurance in respect of the Buyer Credit (and taken for the sole
benefit of the Buyer Credit only) will be affected at the expense of the Borrower. 
  

	9.5.20	Insurance review 

 From
time to time during any period of insurance cover the Agent may review the terms of and identity of brokers, insurance companies and underwriters and war risks or protection and indemnity associations through which the Vessel is insured under this
clause 9.5.20. Such review shall be made in consultation with the Borrower. After consultation, the Borrower shall implement such modifications as the Agent may reasonably request in order to seek to ensure that such insurances at all times cover
all risks which may customarily and generally be covered in transactions similar to that covered by this Agreement and that the terms of such insurances and the identity of brokers, underwriters, insurance companies and associations will continue to
be approved by the Agent, as provided for in clause 9.5.18. 
  

	9.5.21	Insurances effected by the Agent 

 If the Borrower fails to effect or keep in force the Insurances, the Agent may (but shall not be obliged to) effect and/or keep in force such insurances on the Vessel and such entries in protection and
indemnity or war risks associations as the Agent in its discretion considers desirable having regard to the types of insurances that are required pursuant to this clause 9.5, and the Agent may (but shall not be obliged to) pay any unpaid premiums,
calls or contributions. The Borrower will reimburse the Agent from time to time on demand for all such premiums, calls or contributions paid by the Agent, together with interest at the Default Rate from the date of payment by the Agent until the
date of reimbursement 
  

	9.5.22	Environmental 

 The
Borrower shall comply strictly with the requirements of any legislation relating to pollution or protection of the environment which may from time to time be applicable to the Vessel in any jurisdiction in which the Vessel shall trade and in
particular (if a Vessel is to trade in the United States of America and Exclusive Economic Zone (as defined in the Act)) the Borrower shall comply strictly with the requirements of the United States Oil Pollution Act 1990 (“the
Act”). Before any such trade is commenced and during the entire period during which such trade is carried on, the Borrower shall:- 
  

	 	(a)	pay any additional premiums and satisfy such other conditions required to maintain protection and indemnity cover for oil pollution up to the limit available to the
Borrower for the Vessel in the market; and 

  

	 	(b)	make all such quarterly or other voyage declarations as may from time to time be required by the Vessel’s protection and indemnity association in order to maintain
such cover; and 

  

	 	(c)	in addition to the foregoing (if such trade is in the United States of America and Exclusive Economic Zone): 

 

	 	(i)	obtain and retain a certificate of financial responsibility under the Act in form and substance satisfactory to the United States Coast Guard and upon request provide
the Agent with a copy; and 

  
 61 

	 	(ii)	procure that the protection and indemnity insurances do not contain a US Trading Exclusion Clause or any other provision analogous thereto and upon request provide the
Agent with evidence that this is so; and 

  

	 	(iii)	comply strictly with any operational or structural regulations issued from time to time by any relevant authorities under the Act so that at all times the Vessel falls
within the provisions which limit strict liability under the Act for oil pollution. 

  

	9.6	Operation and Maintenance 

  

	9.6.1	General 

 The Borrower
undertakes in favour of the Lender Finance Parties to comply with the following provisions at all times during the Facility Period until such time as the Vessel is sold except as the Agent may otherwise permit in writing. 

 

	9.6.2	Supply and crewing 

Throughout the Facility Period the Borrower shall procure that the Vessel is manned, victualled, navigated, operated, supplied, fuelled,
maintained and repaired, all at no cost to the Agent. 
  

	9.6.3	Condition of the Vessel 

The Borrower shall procure that the Vessel and every part thereof is kept in a good and safe condition and state of repair, ordinary wear
and tear excepted and shall ensure that all repairs to the Vessel or replacements of lost, damaged or worn parts and equipment in respect of the Vessel, are effected in such a manner so as not to diminish the value of the Vessel and in any event:

  

	 	(a)	consistent with first-class ship ownership, operation and management standards in relation to ships of the Vessel’s age and type; 

 

	 	(b)	so as to maintain the Vessel’s present class, namely 1+HULL+MACH+Liquefied gas carrier/LNG, Shiptype 2G (-163°C, 500 kg/m3., 0.25 bar unrestricted navigation +
VeriSTAR-HULL, + AUT-UMS,+SYS-NEQ-1,+MON-SHAFT, INWATERSURVEY, with the American Bureau of Shipping or the equivalent with another Classification Society approved by the Majority Lenders in writing and in each case free from any overdue
recommendations and conditions affecting the Vessel’s class; and 

  

	 	(c)	so as to comply with the material provisions of all laws and regulations applicable to the Vessel, including, without limitation, Environmental Law and Environmental
Approval, and to maintain all certificates, licences and permits applicable to vessels registered in the state of registration for the time being of the Vessel and to vessels trading to any jurisdiction to which the Vessel may trade from time to
time in any such case. 

  

	9.6.4	Master, officers and crew 

The Master, officers and crew of the Vessel shall be the servants of the Borrower for all purposes whatsoever. The Borrower shall ensure
that the wages and allotments and the insurance and pension contributions as appropriate of the Master, officers and crew shall be paid when due and all deductions from their wages in respect of tax liability shall be properly accounted for and the
Master shall have no valid claim for disbursements other than those incurred by him in the ordinary course of trading of the Vessel. 

  
 62 

	9.6.5	Modifications 

 The
Borrower shall procure that no modification is made to the Vessel, unless such modification is required to be made by the Borrower pursuant to clause 5.1 of the Time Charter or is otherwise required under applicable Law or by the Classification
Society, which would: 
  

	 	(a)	materially and adversely alter the structure, type or performance characteristics of the Vessel; or 

 

	 	(b)	reduce the value of the Vessel, 

and the Borrower shall notify the Agent of any modifications which are made to the Vessel the cost of which exceeds or will when
completed exceed two million Dollars ($2,000,000). 
  

	9.6.6	Surveys 

 The Borrower
shall procure that the Vessel is submitted to such periodical or other surveys as may be required by the Flag State or for classification purposes and shall comply with all conditions and recommendations affecting the Vessel’s class of the
relevant Classification Society of the Vessel from time to time in accordance with their terms unless waived and the Borrower shall supply copies of any survey reports to the Agent upon request from the Agent. 

 

	9.6.7	Drydocking 

 The Borrower
shall procure that the Vessel is drydocked as often as may be required to ensure that the Vessel maintains its Classification with its relevant Classification Society and otherwise in accordance with good commercial practice. If the Borrower fails
to comply with the requirements of the relevant Classification Society, the Agent may inspect the Vessel in accordance with clause 9.6.12. If requested by the Agent, the Borrower shall give the Agent reasonable prior written notice of any intended
drydocking of the Vessel. 
  

	9.6.8	Release from arrest 

 The
Borrower shall promptly pay and discharge all debts, damages, liabilities and outgoings whatsoever which have given or which may reasonably be expected to give rise to maritime, statutory or possessory liens on, or claims enforceable against, the
Vessel or the Insurances or any part thereof. If at any time during the Facility Period any writ or equivalent claim or pleading in admiralty is filed against the Vessel or the Insurances or any part thereof, or the Vessel or the Insurances or any
part thereof is arrested or detained or attached or levied upon pursuant to legal process or purported legal process or in the event of the detention of the Vessel in the exercise or the purported exercise of any such lien or claim as aforesaid
(other than by reason of a Compulsory Acquisition), the Borrower shall procure the release of the Vessel and the Insurances from such arrest, detention, attachment or levy or, as the case may be, the discharge of the writ or equivalent claim or
pleading in admiralty as soon as reasonably practicable and in any event within fourteen (14) days (or such longer period as the Agent may agree acting reasonably) of receiving notice thereof by providing bail or procuring the provision of
security or otherwise as circumstances may require. 
  

	9.6.9	Manuals and technical records 

 The Borrower shall procure that: 
  

	 	(a)	all such records, logs, manuals, technical data and other materials and documents which are required to be maintained in respect of the Vessel to comply with any
applicable laws or the requirements of the Flag State and Classification Society are maintained; 

  

	 	(b)	accurate, complete and up-to-date logs and records of all voyages made by the Vessel and of all maintenance, repairs, alterations, modifications and additions to the
Vessel are kept in accordance with good industry practice; and 

  
 63 

	 	(c)	following the occurrence of an Event of Default and for as long as it is continuing unremedied or unwaived on reasonable advance notice from the Agent, the Agent or its
representatives is permitted at any time to examine and take copies of such logs and records and other records. 

  

	9.6.10	Vessel’s Software 

  

	 	(a)	The Borrower shall obtain and maintain and procure that there are obtained and maintained all licenses and permits (without liability on the part of the Agent for the
payment of any royalties as may be required from time to time in respect of the computer software which is required for the operation of the Vessel, including, but not limited to, navigation software) and shall procure that all such licenses and
permits are granted without any limitation or expiry (or are renewed prior to any such expiry). 

  

	 	(b)	The Borrower shall use its best endeavors to extend to the Security Trustee the benefit of all software licenses and permits in respect of the Vessel which are
available to the Borrower. 

  

	9.6.11	Manager 

 Other than the
Manager, and subject to clause 9.2.18 above, the Borrower shall procure that no commercial or technical manager or construction supervisor of the Vessel is appointed without the prior written consent of the Agent (acting on the instructions of the
Majority Lenders) and KEIC, such consent not to be unreasonably withheld or delayed, and the Borrower shall ensure that the Vessel is at all times under such commercial and technical management. 

 

	9.6.12	Inspection 

 The Borrower
shall ensure that the Agent, its surveyors or other persons appointed by it will be permitted to inspect the Vessel (provided that, if no Event of Default has occurred and is continuing unremedied or unwaived, the Agent may not inspect the Vessel
more than once annually), upon reasonable notice and without interfering with the Vessel’s operation. Such inspections shall be without cost or risk to the Borrower unless an inspection made after the occurrence of an Event of Default that is
continuing unremedied or unwaived, in which case the inspections shall be at the cost of the Borrower and the risk of the Agent. 
  

	9.6.13	Notification of certain events 

 The Borrower shall, immediately upon the same coming to its attention and to the best of its then current knowledge, notify the Agent by electronic mail of: 

 

	 	(a)	any casualty or damage in respect of the Vessel which is or is likely to give rise to a loss or cost or repairs of two million Dollars ($2,000,000) or more;

  

	 	(b)	any occurrence as a result of which the Vessel has become or is, by the passing of time or otherwise, likely to become a Total Loss; 

 

	 	(c)	any requirement or recommendation made by any insurer or Classification Society or by any competent authority which is not complied with within any applicable time
period for compliance stipulated by such authority; 

  

	 	(d)	any arrest or detention of the Vessel, any exercise or purported exercise of any lien on the Vessel or its Earnings or any requisition of the Vessel for hire;

  

	 	(e)	any Environmental Claim made against the Agent of which it is or becomes aware or in connection with the Vessel, or any Environmental Incident or Environmental Claim in
an amount in excess of one million Dollars ($1,000,000) or the Dollar Equivalent (in the case of a claim in any other currency) made against the Borrower, any other Security Party or the Time Charterer in connection with the Vessel;

  
 64 

	 	(f)	any claim for breach of the ISM Code or the ISPS Code being made against the Borrower, any other Security Party or the Time Charterer in connection with the Vessel;

  

	 	(g)	any other matter, event or incident which will or is reasonably likely to lead to the ISM Code or the ISPS Code not being complied with; 

 

	 	(h)	any claims made in connection with a bodily injury to a third party involving amounts in excess of an amount of one million Dollars ($1,000,000) or the Dollar
Equivalent (in the case of a claim in any other currency); 

  

	 	(i)	any requisition of the Vessel for hire; 

  

	 	(j)	any security interest (other than a Permitted Encumbrance) arising over the Vessel or the Insurances or Requisition Compensation; and 

 

	 	(k)	any other event in respect of the Vessel or the Insurances or Requisition Compensation which could reasonably be expected to involve the Agent in any loss or liability,

 and the Borrower shall keep the Agent advised in writing on a regular basis and in such reasonable detail as
the Agent shall require in respect of those events or matters and/or of the response to any of those events or matters by the Borrower or the applicable Security Party, the Time Charterer or any other person. 

 

	9.6.14	Restrictions on chartering or parting with possession 

 The Borrower shall not, without the prior written consent of the Agent acting on the instructions of the Majority Lenders (acting reasonably, and without unreasonable delay): 

 

	 	(a)	let or otherwise charter the Vessel to any other party or allow the Vessel to be used by or available to any other party, except pursuant to the Time Charter or except
as required by the Time Charterer under the Time Charter; 

  

	 	(b)	make any amendment to the Time Charter (other than as permitted under clause 9.1.15(b)), or waive any material provision of such Time Charter, or terminate such Time
Charter; 

  

	 	(c)	put the Vessel into the possession of any person for the purpose of work being done upon it in an amount exceeding or likely to exceed two million Dollars ($2,000,000)
or the equivalent in any other currency (in the case of a claim in any other currency) unless either: 

  

	 	(i)	the cost of such work is covered by Insurances; or 

  

	 	(ii)	the Borrower establishes to the reasonable satisfaction of the Agent that it has sufficient funds to pay for the cost of such work. 

Provided always that this clause 9.6.14(c) shall not apply in respect of the regularly scheduled dry docking of the Vessel for which the
Borrower has reserved amounts in accordance with clause 8.2. 
  

	9.6.15	Additional Vessel Covenants 

 The Borrower further covenants with the Agent in respect of the Vessel:- 
  

	 	(a)	at and from the Delivery Date to effect and maintain registration of the Mortgage at the Vessel’s Vessel Registry; and not cause nor permit to be done any act or
omission as a result of which that registration or the registration set out in clause 9.1.23 above might be defeated or imperilled; and 

  
 65 

	 	(b)	in the event of any requisition or seizure of the Vessel, to take all lawful steps to recover possession of the Vessel as soon as it is entitled to do so; and

  

	 	(c)	to give to the Agent from time to time during the Facility Period on request such information as the Agent may reasonably require with regard to the Vessel’s
employment, position and state of repair; and 

  

	 	(d)	not during hostilities (whether or not a state of war shall formally have been declared and including, without limitation, any civil war) to permit the Vessel to be
employed in carrying any goods which may be declared to be contraband of war or which may render that Vessel liable to confiscation, seizure, detention or destruction, nor to permit the Vessel to enter any area which is declared a war zone by any
governmental authority or by the Vessel’s insurers unless the Borrower has effected at its own expense such additional insurances as shall be necessary or customary for first class ship owners. The Borrower shall promptly notify the Agent
thereof and, if required by the Agent, specifically assign those insurances to the Security Trustee by such documents as the Agent, acting reasonably, may require; and 

 

	 	(e)	not without the prior written consent of the Agent to enter into any agreement or arrangement for sharing the Earnings; and 

 

	 	(f)	to take all reasonable precautions to prevent any infringements of any anti drug legislation in any jurisdiction in which the Vessel shall trade and in particular (if
the Vessel is to trade in the United States of America) to take all reasonable precautions to prevent any infringements of the Anti-Drug Abuse Act of 1986 of the United States of America and for this purpose, if required, to enter into a
“Carrier Initiative Agreement” with the United States’ Customs Service and to procure that the same or a similar agreement is maintained in full force and effect and that the Borrower’s obligations thereunder are performed in
respect of the Vessel. 

  

	10	Events of Default 

  

	10.1	The Agent’s rights 

If any of the events set out in clause 10.2 occurs, the Agent may at its discretion (and, on the instructions of the Majority Lenders,
will): 
  

	10.1.1	by notice to the Borrower declare the Lenders to be under no further obligation to the Borrower under or pursuant to this Agreement and may (and, on the instructions of
the Majority Lenders, will) declare all or any part of the Lender Indebtedness (including such unpaid interest and Commitment Fees as shall have accrued and any Break Costs incurred by the Lender Finance Parties) to be immediately payable, whereupon
the Lender Indebtedness (or the part of the Lender Indebtedness referred to in the Agent’s notice) shall immediately become due and payable without any further demand or notice of any kind; and/or 

 

	10.1.2	declare that any undrawn portion of the Loan shall be cancelled, whereupon the same shall be cancelled and the corresponding Commitment of each Lender shall be reduced
to zero; and/or 

  

	10.1.3	exercise any rights and remedies in existence or arising under the Security Documents. 

 

	10.2	Events of Default 

 The
events referred to in clause 10.1 are:- 
  

	10.2.1	Failure to Pay: any Security Party fails to pay any amount payable by it under this Agreement or any of the Security Documents at the time, in the currency and
otherwise in the manner specified herein or therein (and so that, for this purpose, sums payable on demandunscheduled amounts shall be treated as having been paid at the stipulated time if paid within five (5) days of
demand) unless in respect of scheduled payments the Borrower demonstrates to the satisfaction of the Agent that such failure has occurred by reason solely of banking error and such sum remains unpaid for no longer than five (5) days after the
date on which it receives notice from the Agent of such failure; or 

  
 66 

	10.2.2	if any of the Borrower, the Sponsors or the Borrower Shareholders fails to pay when due any amount payable by it under any of the Project Documents to which it is a
party at any time, in the currency and otherwise in the manner specified therein subject to expiry of any applicable grace periods specified therein and if such failure in the reasonable opinion of the Agent (acting on the instructions of the
Majority Lenders) has or may be likely to have a Material Adverse Effect; or 

  

	10.2.3	Insurances: any of the Insurances required to be placed and maintained in respect of the Vessel in accordance with clause 9.5 are not so placed and/or maintained
or if at any time any of the Insurances either: 

  

	 	(a)	lapse before the time of scheduled renewal without being renewed in accordance with clause 9.5; or 

 

	 	(b)	are not renewed at the time of scheduled renewal in accordance with the requirements of clause 9.5; or 

 

	 	(c)	are cancelled or rendered invalid, void or unenforceable, 

  

	    	any sums recovered under any of the Insurances for the Vessel are or become repayable in whole or in part and an equivalent amount is not paid by the Borrower within 2
Business Days; or 

  

	10.2.4	Misrepresentation: any representation or statement made by any Security Party in favour of a Lender Finance Party in this Agreement or any Security Document to
which it is a party or, in each case, in any notice or other document, certificate or statement delivered by it pursuant thereto or in connection therewith is or proves to have been incorrect or misleading in any material respect when made and in
each case where the incorrectness is in the opinion of the Agent (acting on the instructions of the Majority Lenders) remediable and the relevant Security Party shall have failed to remedy it within fifteen (15) days after receipt by the
relevant Security Party of a written notice from the Agent of such failure (or such longer period as the Agent (acting on the instructions of the Majority Lenders) may specify or agree); or 

 

	10.2.5	Specific Covenants: the Borrower fails duly to perform or comply with any of the obligations expressed to be assumed by or procured by it under clauses 9.1.4,
9.1.15,9.1.15(a), 9.1.15(b)(i), 9,1.l5(b)(ii) 9.1.18, 9.1.19,9.1.19, 9.2.17, 9.4.7, 9.4.8, 9.4.9 or 9.4.10 at any time; or 

 

	10.2.6	Other Obligations: (a) a Security Party fails duly to perform or comply with any other term or condition of any other Security Document to which it is a
party (other than those referred to in clauses 10.2.1, 10.2.2, 10.2.4, 10.2.5, 10.2.23, 10.2.24 or 10.2.25) and such failure is not remedied within fifteen (15) days after the Agent has given written notice thereof to the relevant Security
Party (or such longer period as the Agent (acting on the instructions of the Majority Lenders) may specify or agree) or (b) any Security Party fails duly to perform or comply with any other term or condition of any Project Document to which it
is a party subject to expiry of any applicable grace period therein and if the failure to perform in the reasonable opinion of the Agent (acting on the instructions of the Majority Lenders) has or may be likely to have a Material Adverse Effect; or

  

	10.2.7	Cross-Default: any Financial Indebtedness of the Borrower in an amount greater than two hundred and fifty thousand Dollars ($250,000) is not paid when due or
becomes (whether by declaration or automatically in accordance with the relevant agreement or instrument constituting the same and following expiry of any applicable grace period for payment thereof) due and payable prior to the date when it would
otherwise have become due (unless as a result of the exercise by the Borrower of a voluntary right of prepayment), or any creditor of the Borrower becomes entitled to declare any such Financial Indebtedness due and payable or any facility or
commitment available to the Borrower relating to such Financial Indebtedness is withdrawn, suspended or cancelled by reason of any default (however described) of the Borrower concerned; or 

  
 67 

	10.2.8	Litigation: any litigation, arbitration or administrative action or proceeding is commenced against any Security Party or, prior to
Delivery, the Builder or the Refund Guarantor or any of theirits property, undertakings or assets before any court, arbitrator or administrative agency or authority which, if adversely determined, would have in the
reasonable opinion of the Agent a Material Adverse Effect unless: 

  

	 	(a)	the relevant Security Party demonstrates in writing to the Agent (who shall act reasonably in considering such matters) to the Agent’s satisfaction, that such
litigation, arbitration or administrative action or proceeding is or may reasonably be considered to be vexatious or frivolous; or 

  

	 	(b)	it is dismissed or irrevocably stayed within thirty (30) days of commencement; 

 

	10.2.9	Legal process: 

  

	 	(a)	any final judgment or order greater than two hundred and fifty thousand Dollars ($250,000) made against the Borrower is not stayed or complied with within twenty
(20) Business Days or a creditor attaches or takes possession of, or a distress, execution, sequestration or other process is levied or enforced upon or sued out against, all or a substantial part of (in the reasonable opinion of the Agent) the
undertakings, assets, rights or revenues of the Borrower and is not discharged within twenty (20) Business Days; or 

  

	 	(b)	any final judgment or order made against any Security Party (other than the Borrower and (following the Delivery Date) the Supervisor) is not stayed or complied with
within twenty (20) Business Days or a creditor attaches or takes possession of, or a distress, execution, sequestration or other process is levied or enforced upon or sued out against, all or substantially all of (in the reasonable opinion of
the Agent) the undertakings, assets, rights or revenues of any Security Party (other than the Borrower and (following the Delivery Date) the Supervisor) and is not discharged within twenty (20) Business Days and, in each such case above, the
event described above has or might reasonably be likely to have a Material Adverse Effect; or 

  

	10.2.10	Insolvency: any Security Party (including the Supervisor prior to the Delivery Date only) is unable or admits inability to pay its debts as they fall due;
suspends making payments on any of its debts or announces an intention to do so; becomes insolvent; has assets the value of which is less than the value of its liabilities; or suffers the declaration of a moratorium in respect of any of its
indebtedness; or 

  

	10.2.11	Reduction or loss of capital: a meeting is convened by any Security Party (including the Supervisor prior to the Delivery Date only) for the purpose of passing
any resolution to purchase, reduce or redeem any of its share capital (other than a stock buy-back of any Sponsor); or 

  

	10.2.12	Winding up: any corporate action, legal proceedings or other procedure or step is taken for the purpose of winding up any Security Party (including the
Supervisor prior to the Delivery Date only) or an order is made or resolution passed for the winding up of any Security Party (including the Supervisor prior to the Delivery Date only) or a notice is issued convening a meeting for the purpose of
passing any such resolution, provided however that, in the case only of an order for winding-up, the occurrence of such event shall not constitute an Event of Default if such winding-up has commenced as part of a process of a fully-solvent
reorganisation, previously approved by the Agent acting on the instructions of the Majority Lenders and which shall not have a Material Adverse Effect, provided further that the Agent shall not have the right to approve a fully-solvent
reorganisation of any of the Sponsors, the Borrower Shareholders, the Manager or the Sub-Manager; or 

  
 68 

	10.2.13	Administration: any petition is presented, notice given or other step is taken for the purpose of the appointment of an administrator of any Security Party
(including the Supervisor prior to the Delivery Date only) or an administration order is made in relation to any Security Party (including the Supervisor prior to the Delivery Date only); or 

 

	10.2.14	Appointment of receivers and managers: any administrative or other receiver is appointed of any Security Party (including the Supervisor prior to the Delivery
Date only) or any part of its assets and/or undertaking or any other steps are taken to enforce any Encumbrance over all or any part of the assets of any Security Party (including the Supervisor prior to the Delivery Date only); or

  

	10.2.15	Compositions: any corporate action, legal proceedings or other procedures or steps are taken, or negotiations commenced, by any Security Party (including the
Supervisor prior to the Delivery Date only) or by any of its creditors with a view to the general readjustment or rescheduling of all or a material part of its indebtedness or to proposing any kind of composition, compromise or arrangement involving
such company and any of its creditors; or 

  

	10.2.16	Analogous proceedings: there occurs, in relation to any Security Party (including the Supervisor prior to the Delivery Date only) in any country or territory in
which any of them carries on business or to the jurisdiction of whose courts any part of their assets is subject, any event which, in the reasonable opinion of the Agent, appears in that country or territory to correspond with, or have an effect
equivalent or similar to, any of those mentioned in clauses 10.2.9 to 10.2.15 (inclusive) (other than clause 10.2.10) or any Security Party (including the Supervisor prior to the Delivery Date only) otherwise becomes subject, in any such country or
territory, to the operation of any law relating to insolvency, bankruptcy or liquidation; or 

  

	10.2.17	Environmental Incidents: there is an Environmental Incident which gives rise, or may be likely to give rise, to Environmental Claims which would reasonably be
expected to have a Material Adverse Effect; or 

  

	10.2.18	Repudiation: any Security Party repudiates any Security Document or Project Document to which it is a party or does or causes to be done any act or thing
evidencing an intention to repudiate any such Security Document or the Project Document, or if the validity or enforceability of any of the Security Documents and the Project Documents shall at any time and for any reason be contested by any
Security Party which is a party thereto, or if any such Security Party shall deny that it has any, or any further, liability thereunder; or 

  

	10.2.19	Cessation of business: any Security Party (including the Supervisor prior to the Delivery Date only) suspends or ceases (or, in the case of the Borrower, any of
the Borrower Shareholders and/or any of the Sponsors threatens to suspend or cease) to carry on its business (or, in the case of the Sponsors a substantial part of its business where the suspension or cessation of such substantial part of its
business has or might have a Material Adverse Effect) except (in the case of the Security Parties (which shall not for this purpose include the Borrower for the purposes of and followed by a reconstruction, amalgamation, reorganisation, merger or
consolidation which shall be undertaken and concluded in such manner as in the reasonable opinion of the Agent will enable such Security Party to perform its obligations pursuant to the Security Documents or Project Documents to which it is a party;
or 

  

	10.2.20	Seizure: all or a material part of the undertaking, assets, rights or revenues of, or shares or other ownership interests in, any Security Party (including the
Supervisor prior to the Delivery Date only) are seized, nationalised, expropriated or compulsorily acquired by or under the authority of any government; or 

 

	10.2.21	Encumbrances enforceable: any Encumbrance (other than Permitted Encumbrance) in respect of any of the property which is the subject of any of the Security
Documents becomes enforceable; or 

  

	10.2.22	Challenge to Registration: if the registration of the Vessel or the Mortgage becomes void or voidable or subject to cancellation or termination; or

  
 69 

	10.2.23	Swap Agreements: (a) an Event of Default (in each case as defined in any of the Swap Agreements) on the part of the Borrower has occurred and is continuing
unremedied or unwaived under any of the Swap Agreements or (b) an Early Termination Date (as defined in any of the Swap Agreements) has occurred or been or become capable of being effectively designated under any of the Swap Agreements or
(c) a person entitled to do so gives notice of an Early Termination Date under any of the Swap Agreements or (d) any of the Swap Agreements is terminated, cancelled, suspended, rescinded or revoked or otherwise ceases to remain in full
force and effect for any reason; or 

  

	10.2.24	Material Events: save (in respect of the security interests created by any of the Security Documents) where the Borrower has taken such action as the Agent
requires pursuant to clause 9.1.12 (Further Assurance) to adequately protect the security interests created by the Security Documents, any other event occurs or circumstance arises which materially and adversely affects the security interests
created by any of the Security Documents or the Refund Guarantee unless the relevant Security Document(s) and/or the Refund Guarantee is replaced or amended to the satisfaction of the Agent forthwith in the case of this Agreement, the Mortgage, the
Refund Guarantee and the Deed of Covenants or within 21 days in the case of the other Security Documents; or 

  

	10.2.25	KEIC Buyer Credit Policy: The obligation of KEIC under the KEIC Buyer Credit Policy shall terminate, become unenforceable or otherwise cease to be in full force
and effect as a result of the acts or omissions of the Borrower. 

  

	10.3	Replacement of Manager or Supervisor: 

  

	    	notwithstanding any other provision of the Security Documents, no action or omission by or other matter relating to the Manager or the Supervisor shall result in a
misrepresentation, breach of warranty, breach of undertaking, Potential Event of Default or Event of Default hereunder if: 

  

	 	(a)	such misrepresentation, breach of warranty, breach of undertaking, Potential Event of Default or Event of Default is cured or waived; or 

 

	 	(b)	subject to clause 9.2.18 the Manager or Supervisor is replaced by another person reasonably acceptable to the Agent, 

 

	    	in either case within 30 days of the date upon which such action, omission or matter would otherwise have been a misrepresentation, breach, Potential Event of Default
or Event of Default and if the Manager or Supervisor is replaced as set out above they shall be replaced on similar terms to the Management Agreement or Supervision Agreement as appropriate subject always to any misrepresentation, breach, Potential
Event of Default or Event of Default being remedied within a reasonable period by such replacement. 

  

	11	Set-Off and Lien 

  

	11.1	Set-off 

  

	11.1.1	The Borrower irrevocably authorises each of the Lender Finance Parties at any time after all or any part of the Lender Indebtedness shall have become due and payable to
set off any liability of the Borrower to any of the Lender Finance Parties (whether present or future, actual or contingent, and irrespective of the branch or office, currency or place of payment) against any credit balance from time to time
standing on any account of the Borrower (whether current or otherwise and whether or not subject to notice) with any branch of any of the Lender Finance Parties in or towards satisfaction of the Lender Indebtedness and, in the name of that Lender
Finance Party or the Borrower, to do all acts (including, without limitation, converting or exchanging any currency) and execute all documents which may be required to effect such application. The relevant Lender Finance Party will notify the
Borrower forthwith upon the exercise or purported exercise of any rights under this clause 11.1. 

  
 70 

	11.1.2	For such purposes, each Lender Finance Party is authorised to purchase with the moneys standing to the credit of such account such other currencies as may be necessary
to effect such application. No Lender Finance Party shall be obliged to exercise any right given to it by this clause 11.1. The Lender Finance Party shall notify the Borrower forthwith upon the exercise or purported exercise of any right of set-off
giving full details in relation thereto. 

  

	11.1.3	Without prejudice to their rights hereunder and/or under any of the Swap Agreements, the Swap Providers may at the same time as, or at any time after, any Event of
Default under this Agreement or the Borrower’s default under any of the Swap Agreements set-off any amount due now or in the future from the Borrower to the Swap Providers under this Agreement against any amount due from the Swap Providers to
the Borrower under any of the Swap Agreements and apply the first amount in discharging the second amount. The effect of any set-off under this clause 11.1.3 shall be effective to extinguish or, as the case may require, reduce the liabilities of the
Swap Providers under any of the Swap Agreements. 

  

	11.2	Lien 

  

	 	    	If an Event of Default has occurred and is continuing, unremedied or unwaived, each Lender Finance Party shall have a lien on and be entitled to retain and realise as
additional security for the repayment of the Lender Indebtedness any cheques, drafts, bills, notes or negotiable or non-negotiable instruments and any stocks, shares or marketable or other securities and property of any kind of the Borrower (or of
that Lender Finance Party as agent or nominee of the Borrower) from time to time held by that Lender Finance Party, whether for safe custody or otherwise. 

 

	11.3	Restrictions on withdrawal 

  

	    	Despite any term to the contrary in relation to any deposit or credit balance at any time on any account of the Borrower with any of the Lender Finance Parties, no such
deposit or balance shall be repayable or capable of being assigned, mortgaged, charged or otherwise disposed of or dealt with by the Borrower in question after an Event of Default has occurred and while such Event of Default is continuing unremedied
or unwaived, but any Lender Finance Party may from time to time permit the withdrawal of all or any part of any such deposit or balance without affecting the continued application of this clause. Provided always that this clause 11.3 shall not apply
to the Distribution Account or any credit balance therein. 

  

	12	Assignment and Transfer 

  

	12.1	Right to assign 

  

	12.1.1	Subject to clause 12.9, each of the Lenders may (a) assign or transfer all or any of its rights and/or obligations under or pursuant to the Security Documents or
(b) assign or transfer all or any part of its Commitment any such part being at least US $5,000,000 and an integral multiple of US $1,000,000, (i) to any other branch or Affiliate of that Lender (provided that such Affiliate shall have the
same or a better credit rating than the Lender making the assignment or transfer) to another Lender or (ii) above with the prior written consent of the Agent (which shall not be unreasonably withheld or delayed) and the Borrower (which shall
not be unreasonably withheld or delayed and shall not be required if an Event of Default has occurred and is continuing unremedied or unwaived) to any other bank or financial institution provided that in relation to any transfer or any assignment
under this clause 12.1: 

  

	 	(i)	any transferee under this clause 12.1(a) shall assume all of the relevant Lender’s obligations; 

 

	 	(ii)	the Borrower shall not be liable to pay any costs, charges or expenses of or in connection with the implementation of completion of the assignment or transfer;

  

	 	(iii)	the Borrower shall not, as at the time of any such assignment or transfer, be liable to pay any additional or increased amounts or taxes or suffer a reduction in any
amounts receivable by it under this Agreement for which it would not have been liable or would not have suffered but for such assignment or transfer having then taken place; and 

  
 71 

	 	(iv)	the relevant Lender shall give the Borrower five (5) Business Days prior written notice of any intended transfer of obligations. 

 

	12.1.2	Each of the Lenders may, without being restricted or otherwise being bound by clause 12.1.1, assign or transfer all or any part of its rights under or pursuant to this
Agreement and/or any of the other Security Documents to KEIC following the occurrence of an Event of Default which is continuing unremedied or unwaived or otherwise if required to do so by KEIC pursuant to the terms of the KEIC Buyer Credit Policy
provided that KEIC pays first the insurance proceeds in accordance with the KEIC Buyer Credit Policy. 

  

	12.2	Borrower’s co-operation 

  

	    	The Borrower will, at no cost to the Borrower, co-operate fully and will procure that the other Security Parties co-operate fully with the Lender Finance Parties in
connection with any assignment or transfer pursuant to clause 12.1; will execute and procure the execution of such documents as the Lender Finance Parties may reasonably require in connection therewith; and irrevocably authorise each of the Lender
Finance Parties to disclose to any proposed assignee or transferee (whether before or after any assignment or transfer and whether or not any assignment or transfer shall take place) all information relating to the Security Parties, the Time
Charterer, the Loan or the Relevant Documents which each such Lender Finance Party may in its discretion consider necessary to implement such assignment or transfer (subject to any duties of confidentiality applicable to the Borrower and/or Lender
Finance Parties). 

  

	12.3	Rights of assignee 

  

	    	Any assignee or transferee of a Lender shall (unless limited by the express terms of the assignment or transfer) take the full benefit of every provision of the
Security Documents benefiting that Lender. Such transfer shall not directly result in an increased cost to, or liability of, the Borrower at the time of transfer. 

 

	12.4	Transfer Certificates 

  

	    	 If any Lender wishes to transfer all or any of its Commitment as contemplated in clause 12.1 then such transfer may be effected by the delivery to the
Agent of a duly completed and duly executed Transfer Certificate in which event, on the later of the Transfer Date specified in such Transfer Certificate and the fifth (5th) Business Day after the date of delivery of such Transfer Certificate to the Agent: 

 

	12.4.1	to the extent that in such Transfer Certificate the Lender which is a party thereto seeks to transfer its Commitment in whole, the Borrower and such Lender shall be
released from further obligations towards each other under this Agreement and their respective rights against each other shall be cancelled other than existing claims against such Lender for breach of this Agreement (such rights, benefits and
obligations being referred to in this clause 12.4 as “discharged rights and obligations”); 

  

	12.4.2	the Borrower and the Transferee which is a party thereto shall assume obligations towards each other and/or acquire rights against each other which differ from such
discharged rights and obligations only insofar as the Borrower and such Transferee have assumed and/or acquired the same in place of the Borrower and such Lender; 

 

	12.4.3	the Lender Finance Parties and the Transferee shall acquire the same rights and benefits and assume the same obligations between themselves as they would have acquired
and assumed had such Transferee been an original party to this Agreement as a Lender with the rights, benefits and/or obligations acquired or assumed by it as a result of such transfer; and 

 

	12.4.4	as between the Agent and the Transferee, the Transferee shall pay to the Agent a transfer fee of three thousand Dollars ($3,000). 

  
 72 

	12.5	Power of Attorney 

  

	    	In order to give effect to each Transfer Certificate the Lender Finance Parties and the Borrower hereby irrevocably and unconditionally appoint the Agent as its true
and lawful attorney with full power to execute on their respective behalves each Transfer Certificate delivered to the Agent pursuant to clause 12.4 without the Agent being under any obligation before doing so to take any further instructions from
or give any prior notice to, any of the Lender Finance Parties or, subject to the Borrower’s rights under clause 12.1, the Borrower. The Agent shall so execute each such Transfer Certificate on behalf of the other Lender Finance Parties and the
Borrower immediately on receipt of the same by the Agent pursuant to clause 12.4. 

  

	12.6	Notification 

  

	    	The Agent shall promptly notify the other Lender Finance Parties, the Transferee and the Borrower on the execution by it of any Transfer Certificate together with
details of the amount transferred, the Transfer Date and the parties to such transfer. 

  

	12.7	No Assignment or transfer by the Borrower 

  

	    	The Borrower may not assign any of its rights or transfer any of its rights or obligations under the Security Documents without the prior written consent of the Lenders
and KEIC. 

  

	12.8	KEIC Buyer Credit Policy 

  

	    	Not withstanding any provisions to the contrary in this Agreement, in the event KEIC pays the insurance proceeds in full or in part in accordance with the KEIC Buyer
Credit Policy, (i) the obligations of the Borrower under this Agreement shall not be reduced or affected in any manner, (ii) KEIC shall be entitled to exercise the rights of the Lenders in accordance with clause 9.2 of the Intercreditor
Deed, (iii) the provisions of clause 9.1 of the Intercreditor Deed shall apply and (iv) with respect to the obligations of the Borrower owed to the Agent, the Security Trustee and/or the Lenders under the Security Documents (or any of
them) such obligations shall additionally be owed to KEIC to the extent of its interest by way of subrogation of the rights of the Lenders. 

  

	12.9	KEIC Consent 

  

	    	A Lender may not assign or transfer its portion of the Buyer Credit or any part thereof without the consent of KEIC (such consent not to be unreasonably withheld or
delayed). 

  

	13	Payments, Reserve Requirements and Illegality 

  

	13.1	Payments 

  

	    	All amounts payable by the Borrower to the Lender Finance Parties under or pursuant to any of the Security Documents shall be paid to such accounts at such banks as the
Agent may from time to time direct to the Borrower and shall be paid in Dollars in same day funds (or such funds as are required by the authorities in the United States of America for settlement of international payments for immediate value).
Payments shall be deemed to have been received by the Agent on the date on which the Agent receives authenticated advice of receipt, unless that advice is received by the Agent on a day other than a Business Day or at a time of day (whether on a
Business Day or not) when the Agent in its reasonable discretion considers that it is impossible or impracticable for the Agent to utilise the amount received for value that same day, in which event the payment in question shall be deemed to have
been received by the Agent on the Business Day next following the date of receipt of advice by the Agent. 

  

	13.2	No deductions or withholdings 

  

	    	All payments (whether of principal or interest or otherwise) to be made by the Borrower to the Lender Finance Parties pursuant to the Security Documents shall, subject
only to clause 13.3, be made free and clear of and without deduction for or on account of any Taxes or other deductions, withholdings, restrictions, conditions or counterclaims of any nature, and the Borrower will not claim any equity in respect of
any payment due from them to the Lender Finance Parties under or in relation to any of the Security Documents. 

  
 73 

	13.3	Grossing-up 

  

	13.3.1	If at any time any law requires (or is interpreted by any relevant fiscal authority to require) the Borrower to make any deduction or withholding from any payment, or
to change the rate or manner in which any required deduction or withholding is made, the Borrower will promptly notify the Agent and, simultaneously with making that payment, will pay to the Agent whatever additional amount (after taking into
account any additional Taxes on, or deductions or withholdings from, or restrictions or conditions on, that additional amount) is necessary to ensure that, after making the deduction or withholding, the Agent and the Lenders receive a net sum equal
to the sum which they would have received had no deduction or withholding been made. 

  

	13.3.2	If following the making of any such increased payment by the Borrower pursuant to clause 13.3.1, the Agent or any Lender determines that: 

 

	 	(a)	a credit against, relief or remission for, or repayment of any Tax (a “Tax Credit”) is attributable to any deduction or withholding or increased
payment made by the Borrower; and 

  

	 	(b)	it has obtained, utilised and retained that Tax Credit, 

  

	    	the Agent or Lender (as appropriate) shall pay an amount to the Borrower which the Agent or the Lender (as appropriate) determines will leave it (after that payment) in
the same after-Tax position as it would have been had the deduction or withholding or additional payment not been required to be made. 

  

	13.4	Evidence of deductions 

  

	    	If at any time the Borrower is required by law to make any deduction or withholding from any payment to be made by it to the Lender Finance Parties pursuant to any of
the Security Documents, the Borrower will pay the amount required to be deducted or withheld to the relevant authority within the time allowed under the applicable law and will, no later than thirty (30) days after making that payment, deliver
to the Agent an original receipt issued by the relevant authority, or other evidence reasonably acceptable to the Agent, evidencing the payment to that authority of all amounts required to be deducted or withheld. If the Borrower makes any deduction
or withholding from any payment to the Lender Finance Parties under or pursuant to any of the Security Documents, and a Lender subsequently receives a refund or allowance from any tax authority which that Lender at its sole discretion (acting
reasonably and in good faith) identifies as being referable to that deduction or withholding, that Lender shall within five (5) Business Days of receipt of the same, pay to the Borrower an amount equal to the amount of the refund or allowance
received, if and to the extent that it may do so without prejudicing its right to retain that refund or allowance and without putting itself in any worse financial position than that in which it would have been had the deduction or withholding not
been required to have been made. Nothing in this clause 13.4 shall be interpreted as imposing any obligation on any Lender to apply for any refund or allowance nor as restricting in any way the manner in which any Lender organises its tax affairs,
nor as imposing on any Lender any obligation to disclose to the Borrower any information regarding its tax affairs or tax computations. All costs and expenses incurred by any Lender in obtaining or seeking to obtain a refund or allowance from any
tax authority pursuant to this clause 13.4 shall be for the Borrower’s account. 

  

	13.5	Adjustment of due dates 

  

	    	If any payment to be made to the Lender Finance Parties under any of the Security Documents, other than a payment of interest on the Loan (to which clause 6.7 applies),
shall be due on a day which is not a Business Day, that payment shall be made on the next succeeding Business Day (unless the next succeeding Business Day falls in the next calendar Month in which event the payment shall be made on the next
preceding Business Day). Any such variation of time shall be taken into account in computing any interest in respect of that payment. 

  
 74 

	13.6	Change in law 

  

	    	If, by reason of the introduction of any law, or any change in any law, or the interpretation by the relevant fiscal authority or administration of any law, or in
compliance with any request or requirement from any central bank or any fiscal, monetary or other authority:- 

  

	13.6.1	any Lender Finance Party (or the Holding Company of any Lender Finance Party) shall be subject to any Tax with respect to payments of all or any part of the Lender
Indebtedness; or 

  

	13.6.2	the basis of Taxation of payments to any Lender Finance Party in respect of all or any part of the Lender Indebtedness shall be changed (other than as a result of any
change in the applicable tax rate in the jurisdiction in which its lending office is based); or 

  

	13.6.3	any reserve requirements shall be imposed, modified or deemed applicable against assets held by or deposits in or for the account of or loans by any branch of any
Lender Finance Party or its direct or indirect Holding Company; or 

  

	13.6.4	any ratio (whether cash, capital adequacy, liquidity or otherwise) which any Lender Finance Party or its direct or indirect Holding Company is required or requested to
maintain shall be affected; or 

  

	13.6.5	there is imposed on any Lender Finance Party (or on the direct or indirect Holding Company of any Lender Finance Party) any other condition in relation to the Lender
Indebtedness or the Security Documents (other than as a result of any change in the applicable tax rate in the jurisdiction in which its lending office is based); 

 

	    	and the result of any of the above shall be to increase the cost to any Lender (or to the direct or indirect Holding Company of any Lender) of that Lender making or
maintaining its Commitment or its Drawing, or to cause any Lender Finance Party to suffer (in its reasonable opinion) a material reduction in the rate of return on its overall capital below the level which it reasonably anticipated at the Execution
Date and which it would have been able to achieve but for its entering into this Agreement and/or performing its obligations under this Agreement, the Lender Finance Party affected shall notify the Agent and, on demand to the Borrower by the Agent,
the Borrower shall from time to time pay to the Agent for the account of the Lender Finance Party affected the amount which shall compensate that Lender Finance Party or the Agent (or the relevant Holding Company) for such additional cost or reduced
return. A certificate signed by an authorised signatory of the Agent or of the Lender Finance Party affected setting out the amount of that payment and the basis of its calculation shall be submitted to the Borrower and shall be conclusive evidence
of such amount save for manifest error or on any question of law. 

  

	    	Notwithstanding the foregoing, this clause 13.6 does not apply to the extent any increased cost is: 

 

	 	(a)	attributable to a tax deduction required by law to be made by the Borrower; 

 

	 	(b)	fully compensated for by clause 15.7 (or would have been compensated for under clause 15.7 but was not so compensated solely because any of the exclusions in clause
15.7 applied) or fully compensated for under any other provision of this Agreement; or 

  

	 	(c)	attributable to the wilful breach by the relevant Lender Finance Party (or the Holding Company of any Lender Finance Party) or any of its or their Affiliates of any
law. 

  
 75 

	13.7	Illegality and impracticality 

  

	    	Notwithstanding anything contained in the Security Documents, the obligations of a Lender to advance or maintain its Commitment shall terminate in the event that a
change in any law or in the interpretation of any law by any authority charged with its administration shall make it unlawful for that Lender to advance or maintain its Commitment. In such event the Lender affected shall notify the Agent and the
Agent shall, by written notice to the Borrower, declare that Lender’s obligations to be immediately terminated. If all or any part of the Loan shall have been advanced by the Lenders to the Borrower, the portion of the Lender Indebtedness
(including all accrued interest and Commitment Fees) advanced by the Lender so affected shall be prepaid on the next Interest Payment Date, or sooner if illegality is determined (but no sooner than the last day of any applicable grace period
permitted by law). Clause 5.4 shall apply to that prepayment if it is made on a day other than the last day of an Interest Period. 

  

	13.8	Changes in market circumstances 

  

	    	If at any time a Lender determines (which determination shall be final and conclusive and binding on the Borrower) that, by reason of changes affecting the London
Interbank market, adequate and fair means do not exist for ascertaining the rate of interest on the Loan or any part thereof pursuant to this Agreement: 

  

	13.8.1	that Lender shall give notice to the Agent and the Agent shall give notice to the Borrower of the occurrence of such event; and 

 

	13.8.2	the Agent shall as soon as reasonably practicable certify to the Borrower in writing the effective cost to that Lender of maintaining its Commitment for such further
period as shall be selected by that Lender and the rate of interest payable by the Borrower for that period; or, if that is not acceptable to the Borrower, 

 

	13.8.3	the Agent in accordance with instructions from that Lender and subject to that Lender’s approval of any agreement between the Agent and the Borrower, will
negotiate with the Borrower in good faith with a view to modifying this Agreement to provide a substitute basis for that Lender’s Commitment which is financially a substantial equivalent to the basis provided for in this Agreement.

  

	    	If, within thirty (30) days of the giving of the notice referred to in clause 13.8.1, the Borrower and the Agent fail to agree in writing on a substitute basis for
such Lender’s Commitment the Borrower will immediately prepay the amount of such Lender’s Commitment and the Maximum Loan Amount will automatically decrease by the amount of such Commitment and such decrease shall not be reversed. Clause
5.4 shall apply to that prepayment if it is made on a day other than the last day of an Interest Period. 

  

	13.9	Non-availability of currency 

  

	    	If a Lender is for any reason unable to obtain Dollars in the London Interbank market and is, as a result, or as a result of any other contingency affecting the London
Interbank market, unable to advance or maintain its Commitment in Dollars, that Lender shall give notice to the Agent and the Agent shall give notice to the Borrower and that Lender’s obligations to make the Loan available shall immediately
cease. In that event, if all or any part of the Loan shall have been advanced by that Lender to the Borrower, the Agent in accordance with instructions from that Lender and subject to that Lender’s approval of any agreement between the Agent
and the Borrower, will negotiate with the Borrower in good faith with a view to establishing a mutually acceptable basis for funding the Loan or relevant part thereof from an alternative source. If the Agent and the Borrower have failed to agree in
writing on a basis for funding the Loan or relevant part thereof from an alternative source by 11.00 a.m. on the second Business Day prior to the end of the then current relevant Interest Period, the Borrower will (without prejudice to its other
obligations under or pursuant to this Agreement, including, without limitation, its obligation to pay interest on the Loan, arising on the expiry of the then relevant Interest Period) prepay the Lender Indebtedness (or relevant part thereof) to the
Agent on behalf of that Lender on the expiry of the then current relevant Interest Period. 

  
 76 

	13.10	Mitigation 

  

	13.10.1	Each Lender Finance Party shall, subject to clause 13.10.2 below, in consultation with the Borrower, take all reasonable steps to mitigate any circumstances which arise
and which would result in any amount becoming payable under or pursuant to, or cancelled pursuant to, any of clause 13.3, clause 13.6 or clause 13.7 including (but not limited to) transferring its rights and obligations under the Security Documents
to an Affiliate. 

  

	13.10.2	The Borrower shall indemnify each Lender Finance Party for all costs and expenses properly incurred by that Lender Finance Party as a result of steps taken by it under
clause 13.10.1. A Lender Finance Party is not obliged to take any steps under clause 13.10.1 if, in the opinion of that Lender Finance Party (acting reasonably), to do so might be prejudicial to it. 

 

	14	Communications 

  

	14.1	Method 

  

	    	Any communication may be given, delivered, made or served (as the case may be) under or in relation to this Agreement by letter or fax or (subject to clause 14.3)
electronic mail and shall be in the English language and sent addressed:- 

  

	14.1.1	in the case of any of the Lenders to the Agent at the address specified for BNP Paribas S.A. in Schedule 1; 

 

	14.1.2	in the case of the Agent, at the address specified for BNP Paribas S.A. in Schedule 1; 

 

	14.1.3	in the case of the Security Trustee, at the address specified for BNP Paribas S.A. in Schedule 1; 

 

	14.1.4	in the case of the KEIC Agent, at the address specified for BNP Paribas S.A. in Schedule 1; 

 

	14.1.5	in the case of the Borrower at: 

  

	    	Mitsui & Co., Ltd. 

	    	2-1, Ohtemachi 1-chome, 

	    	Chiyoda-ku, 

	    	Tokyo, 100-0004, 

	    	Japan 

  

	    	Fax: 81-3-3285-9838 

  

	    	Attention: General Manager, LNG Project Department, 

	    	Second Ship & Marine Project Division 

  

	    	Email: tkmyj@dg.mitsui.com 

  

	    	or to such other address or fax number as any of the above parties may designate for themselves by written notice to the others. 

 

	14.2	Timing 

  

	    	A Communication shall be deemed to have been duly given, delivered, made or served to or on, and received by a party to this Agreement:- 

 

	14.2.1	in the case of a fax when the sender receives one or more transmission reports showing the whole of the Communication to have been transmitted to the correct fax
number; 

  

	14.2.2	if delivered to an officer of the relevant party or left at the address of the relevant party specified in clause 14.1; or 

  
 77 

	14.2.3	if posted, at 9.00 a.m. on the fifth Business Day after posting by prepaid first class post. PROVIDED ALWAYS that communications to the Agent and (to the extent that
they relate to the matters specified in clause 4.10.2 of the Intercreditor Deed only) the Lenders and the Borrower shall be effective only upon receipt; or 

 

	14.2.4	if by electronic mail, in accordance with clause 14.3; 

  

	    	Any Communication by fax shall be promptly confirmed in writing by post or hand delivery. 

 

	14.3	Electronic communication 

  

	14.3.1	Any communication to be made in connection with this Agreement may be made by electronic mail or other electronic means, if the Borrower and the relevant Lender Finance
Party: 

  

	 	(a)	agree that, unless and until notified to the contrary, this is to be an accepted form of communication; 

 

	 	(b)	notify each other in writing of their electronic mail address and/or any other information required to enable the sending and receipt of information by that means; and

  

	 	(c)	notify each other of any change to their address or any other such information supplied by them. 

 

	14.3.2	Any electronic communication made between the Borrower and the relevant Lender Finance Party will be effective only when actually received in readable form and
acknowledged by the recipient (it being understood that any system generated responses do not constitute an acknowledgement) and in the case of any electronic communication made by the Borrower to a Lender Finance Party only if it is addressed in
such a manner as the Lender Finance Party shall specify for this purpose. 

  

	14.3.3	Any electronic communication made in accordance with this clause 14.3 shall be confirmed in writing as soon as reasonably practicable thereafter.

  

	15	General Indemnities 

  

	15.1	Currency 

  

	    	In the event of any Lender Finance Party receiving or recovering any amount payable under any of the Security Documents in a currency other than the Currency of
Account, and if the amount received or recovered is insufficient when converted into the Currency of Account at the date of receipt to satisfy in full the amount due, the Borrower shall, on the Agent’s written demand, pay to the Agent such
further amount in the Currency of Account as is sufficient to satisfy in full the amount due and that further amount shall be due to the Agent on behalf of the Lender Finance Parties as a separate debt under this Agreement. 

 

	15.2	Costs and expenses 

  

	    	The Borrower will, on the earlier of (a) the date falling thirty (30) days from the date of the Agent’s written demand and (b) the date of the next
following payment of charterhire under the Time Charter, reimburse the Agent (on behalf of each of the Lender Finance Parties and KEIC) for all reasonable out of pocket expenses including internal and external legal costs (including stamp duty,
Value Added Tax or any similar or replacement tax if applicable but excluding income tax) of and incidental to:- 

  

	15.2.1	the negotiation, preparation, execution and registration of the Security Documents (whether or not any of the Security Documents are actually executed or registered and
whether or not all or any part of the Loan is advanced); 

  

	15.2.2	any amendments, addenda or supplements to any of the Security Documents (whether or not completed); 

  
 78 

	15.2.3	any other documents (including legal opinions) which may at any time be required by any Lender Finance Party to give effect to any of the Security Documents or which
any Lender Finance Party is entitled to call for or obtain pursuant to any of the Security Documents; and 

  

	15.2.4	without prejudice to clauses 15.3 and 15.5, the exercise of the rights, powers, discretions and remedies of the Lender Finance Parties under or pursuant to the Security
Documents. 

  

	15.3	Events of Default 

  

	    	The Borrower shall indemnify the Lender Finance Parties from time to time on demand against all losses and costs incurred or sustained by any Lender Finance Party as a
consequence of any Event of Default, including (without limitation) any Break Costs. 

  

	15.4	Funding costs 

  

	    	The Borrower shall indemnify the Lender Finance Parties from time to time on demand against all losses and costs incurred or sustained by any Lender Finance Party if,
for any reason due to a Potential Event of Default or other action by the Borrower, any Drawing is not advanced to the Borrower after the relevant Drawdown Notice has been given to the Agent, or is advanced on a date other than that requested in the
Drawdown Notice, including (without limitation), any Break Costs. 

  

	15.5	Protection and enforcement 

  

	15.5.1	The Borrower shall indemnify the Lender Finance Parties and KEIC from time to time on demand against all losses, costs and liabilities which any Lender Finance Party or
KEIC may from time to time sustain, incur or become liable for in or about the protection, maintenance or enforcement of the rights conferred on the Lender Finance Parties and KEIC by the Security Documents or in or about the exercise or purported
exercise by the Lender Finance Parties or KEIC of any of the rights, powers, discretions or remedies vested in them under or arising out of the Security Documents, including (without limitation) any losses, costs and liabilities which any Lender
Finance Party or KEIC may from time to time sustain, incur or become liable for by reason of any Lender Finance or KEIC Party being mortgagees of the Vessel, assignees of any Mortgage and/or a Lender to the Borrower, or by reason of any Lender
Finance Party or KEIC being deemed by any court or authority to be an operator or controller, or in any way concerned in the operation or control, of the Vessel. No such indemnity will be given to a Lender Finance Party or KEIC where any such loss,
cost or liability has occurred due to wilful misconduct or recklessness with knowledge of the probable consequences on the part of that Lender Finance Party or KEIC; however this shall not affect the right of any other Lender Finance Party or KEIC
to receive any such indemnity. 

  

	15.5.2	The Agent shall: 

  

	 	(a)	notify the Borrower in writing of any claim made against it of which it is aware which is likely to give rise to such losses, costs and liabilities;

  

	 	(b)	unless an Event of Default has occurred and is continuing, consult, in good faith with the Borrower, in respect of such claim until such date as the Lender Finance
Party is obliged to satisfy or discharge such claim and not enter into any settlement or other compromise in respect of such claim without the prior written consent of the Borrower (which consent shall not be unreasonably withheld or delayed),
unless the Lender Finance Parties expressly waive in writing their right to be indemnified in respect of such losses, costs and liabilities; 

  

	 	(c)	so long as it is indemnified to its satisfaction against costs or liabilities that may be incurred, use reasonable endeavours to defend such claim and to avoid or
reduce the losses, costs and liabilities which may be incurred; and 

  
 79 

	 	(d)	unless an Event of Default has occurred and is continuing, give the Borrower a reasonable opportunity to take such action, at the Borrower’s cost, as the Borrower
deems fit to defend or avoid any liability being incurred or to take action against a third party in respect of any losses (provided that the Borrower may not take any action in the name of the Lender Finance Party without that Lender Finance
Party’s prior written consent nor may the Borrower take any action which would involve risk of criminal or civil liability to the Lender Finance Parties or any material risk of the sale, loss or forfeiture of the Vessel).

  

	15.5.3	The indemnities in this clause 15.5 shall not extend to any claim or liability of a Lender Finance Party to the extent that such claim or liability arises from an act
or omission on the part of that Lender Finance Party which constitutes gross negligence or wilful misconduct on the part of such Lender Finance Party. 

  

	15.6	Liabilities of Lender Finance Parties 

 The Borrower will from time to time reimburse the Lender Finance Parties on demand for all sums which any Lender Finance Party may pay on account of any of the Security Parties or in connection with the
Vessel (whether alone or jointly or jointly and severally with any other person) including (without limitation) all sums which any Lender Finance Party may pay or guarantees which any Lender Finance Party may give in respect of the Insurances, any
expenses incurred by any Lender Finance Party in connection with the maintenance or repair of the Vessel or in discharging any lien, bond or other claim relating in any way to the Vessel, and any sums which any Lender Finance Party may pay or
guarantees which they may give to procure the release of the Vessel from arrest or detention. 
  

	15.7	Taxes 

 The Borrower shall
pay all Taxes imposed on the Lender Finance Parties in respect of the Security Documents or to which all or any part of the Lender Indebtedness or any of the Security Documents or the Project Documents may be at any time subject and shall indemnify
the Lender Finance Parties on demand against all liabilities, costs, claims and expenses incurred in connection therewith, including but not limited to any such liabilities, costs, claims and expenses resulting from any omission to pay or delay in
paying any such Taxes. Provided that the indemnification in this clause 15.7 shall not apply to the extent that the Taxes imposed on a Lender Finance Party arose directly or indirectly from the gross negligence or wilful misconduct of such Lender
Finance Party. The indemnity contained in this clause 15.7 shall survive the repayment of the Lender Indebtedness. 
  

	15.8	Value Added Tax 

 All
amounts set out, or expressed to be payable by the Borrower to the Lender Finance Parties pursuant to the Security Documents which (in whole or in part) constitute consideration for a supply for Value Added Tax purposes shall be deemed to be
exclusive of any Value Added Tax which is chargeable on such supply, and accordingly, if Value Added Tax is chargeable on any supply made by any Lender Finance Party to a Borrower under a Security Document, that Borrower shall pay to the Lender
Finance Party (in addition to and at the same time as paying the consideration) an amount equal to the amount of the Value Added Tax. 
  

	15.9	KEIC Indemnity 

 The
Borrower shall indemnify the KEIC Agent and each Lender from time to time on demand against any duly evidenced additional premium, cost or expense as provided for under the KEIC Buyer Credit Policy, which KEIC may charge, invoice, or set-off against
amounts owing to the KEIC Agent and/or the Lenders, including without limitation as a result of a change of the delivery schedule of the Vessel, a change to Schedule 7 (Contract Instalments and Repayment Profile) of this Agreement or
otherwise, properly incurred by the KEIC Agent or a Lender in connection with their compliance with the KEIC Buyer Credit Policy. 

  
 80 

	16	Miscellaneous 

  

	16.1	Tax Lease 

  

	16.1.1	The Lender Finance Parties agree that the Loan may be refinanced to incorporate a lease financing structure with the prior written consent of each Lender Finance Party.
Each Lender Finance Party agrees that it shall not unreasonably withhold or delay its consent to the implementation of a lease financing structure, provided that: 

 

	 	(a)	it is satisfied that its security position will not be materially and adversely affected; 

 

	 	(b)	it has received agreed and executed documentation acceptable to it in all respects; 

 

	 	(c)	the lease financing structure is not, in its reasonable opinion, unduly onerous in terms of documentation and time; 

 

	 	(d)	it has received credit approval for such lease financing; and 

  

	 	(e)	it has received legal opinions satisfactory to it in relation to jurisdictions reasonably required by it. 

 

	16.1.2	No Lender Finance Party shall be entitled to any additional fees from the Borrower in connection with the implementation of a lease financing structure.

  

	16.1.3	The Borrower shall pay the reasonable costs and expenses (including, without limitation, the reasonable fees and expenses of outside legal counsel engaged by the Lender
Finance Parties) incurred by the Lender Finance Parties in connection with the implementation of the lease finance structure. 

  

	16.2	Waivers 

 No failure or
delay on the part of any Lender Finance Party in exercising any right, power, discretion or remedy under or pursuant to any of the Security Documents, nor any actual or alleged course of dealing between any Lender Finance Party and any of the
Security Parties, shall operate as a waiver of, or acquiescence in, any default on the part of any Security Party, unless expressly agreed to do so in writing by the Agent, nor shall any single or partial exercise by any Lender Finance Party of any
right, power, discretion or remedy preclude any other or further exercise of that right, power, discretion or remedy, or the exercise by a Lender Finance Party of any other right, power, discretion or remedy. 

 

	16.3	No variations 

 No
variation or amendment of any of the Security Documents shall be valid unless made by each party thereto and in accordance with the terms thereof and consented to in writing by KEIC. 

 

	16.4	Severability 

 If at any
time any provision of any of the Security Documents is invalid, illegal or unenforceable in any respect that provision shall be severed from the remainder and the validity, legality and enforceability of the remaining provisions shall not be
affected or impaired in any way. 
  

	16.5	Successors etc. 

 The
Security Documents shall be binding on the Security Parties and on their successors and permitted transferees and assignees, and shall inure to the benefit of the Lender Finance Parties and KEIC in respect of their rights and their respective
successors, transferees and assignees. 
  

	16.6	Further assurance 

 If any
provision of the Security Documents shall be invalid or unenforceable in whole or in part by reason of any present or future law or any decision of any court, then from time to time the Borrower will promptly, following a demand by the Agent,
execute or procure the execution of such further documents as in the reasonable opinion of the Lenders are necessary to provide valid and enforceable security for the repayment of the Lender Indebtedness, provided that with respect to any further
document relating to the Time Charter, the Borrower shall only be required to procure the execution of such documents on a reasonable endeavours basis. 

  
 81 

	16.7	Other arrangements 

 The
Lender Finance Parties may, without prejudice to their rights under or pursuant to the Security Documents, at any time and from time to time, on such terms and conditions as they may in their discretion determine, and with notice to the Borrower,
grant time or other indulgence to, or compound with, any other person liable (actually or contingently) to the Lender Finance Parties or any of them in respect of all or any part of the Lender Indebtedness, and may release or renew negotiable
instruments and take and release securities and hold funds on realisation or suspense account without affecting the liabilities of the Borrower or the rights of the Lender Finance Parties under or pursuant to the Security Documents. 

 

	16.8	Advisers 

 The Borrower
irrevocably authorises the Agent, at any time and from time to time during the Facility Period, to consult insurance advisers on any matters relating to the Insurances, including, without limitation, the collection of insurance claims, and from time
to time to consult or retain advisers or consultants to monitor or advise on any other claims relating to the Vessel. Subject to clause 9.1.22 the Borrower will provide such advisers and consultants with all information and documents which they may
from time to time reasonably require. In the event that such advisers or consultants discover that the Borrower is in breach of its obligations in relation to the Insurances or at the time of or during such consultation or retention there occurs an
Event of Default which is continuing unremedied or unwaived, then the Borrower will reimburse the Agent on demand for all reasonable costs and expenses properly incurred by the Agent in connection with the consultation or retention of such advisers
or consultants, but such consultation or retention shall otherwise be at the Lender Finance Parties’ own cost and expense. 
  

	16.9	Delegation 

 The Lender
Finance Parties may at any time and from time to time delegate to any person any of their rights, powers, discretions and remedies pursuant to the Security Documents, other than rights relating to actions to be taken by the Majority Lenders or the
Lenders as a group, on such terms as they may consider appropriate (including the power to sub-delegate). 
  

	16.10	Rights etc. cumulative 

Every right, power, discretion and remedy conferred on the Lender Finance Parties under or pursuant to the Security Documents shall be
cumulative and in addition to every other right, power, discretion or remedy to which they may at any time be entitled by law or in equity. The Lender Finance Parties may exercise each of their rights, powers, discretions and remedies as often and
in such order as they deem appropriate subject to obtaining the prior written consent of the Majority Lenders. The exercise or the beginning of the exercise of any right, power, discretion or remedy shall not be interpreted as a waiver of the right
to exercise any other right, power, discretion or remedy either simultaneously or subsequently. 
  

	16.11	No enquiry 

 The Lender
Finance Parties shall not be concerned to enquire into the powers of the Security Parties or of any person purporting to act on behalf of any of the Security Parties, even if any of the Security Parties or any such person shall have acted in excess
of their powers or if their actions shall have been irregular, defective or informal, whether or not any Lender Finance Parties had notice thereof. 

  
 82 

	16.12	Continuing security 

 The
security constituted by the Security Documents shall be continuing and shall not be satisfied by any intermediate payment or satisfaction until the Indebtedness shall have been repaid in full and none of the Lender Finance Parties shall be under any
further actual or contingent liability to any third party in relation to the Vessel, the Insurances, Earnings or Requisition Compensation or any other matter referred to in the Security Documents. 

 

	16.13	Security cumulative 

 The
security constituted by the Security Documents shall be in addition to any other security now or in the future held by the Lender Finance Parties or any of them for or in respect of all or any part of the Lender Indebtedness, and shall not merge
with or prejudice or be prejudiced by any such security or any other contractual or legal rights of any of the Lender Finance Parties, nor affected by any irregularity, defect or informality, or by any release, exchange or variation of any such
security. Section 93 of the Law of Property Act 1925 and all provisions which the Agent considers analogous thereto under the law of any other relevant jurisdiction shall not apply to the security constituted by the Security Documents.

  

	16.14	No liability 

 None of the
Lender Finance Parties, nor any agent or employee of any Lender Finance Party, nor any receiver and/or manager appointed by the Agent, shall be liable for any losses which may be incurred in or about the exercise of any of the rights, powers,
discretions or remedies of the Lender Finance Parties under or pursuant to the Security Documents nor liable as mortgagee in possession for any loss on realisation or for any neglect or default of any nature for which a mortgagee in possession might
otherwise be liable unless such Lender Finance Party’s action constitutes wilful misconduct or recklessness with knowledge of the probable consequences. 
  

	16.15	Rescission of payments etc. 

 Any discharge, release or reassignment by any of the Lender Finance Parties of any of the security constituted by, or any of the obligations of any Security Party contained in, any of the Security
Documents shall be (and be deemed always to have been) void if any act (including, without limitation, any payment) as a result of which such discharge, release or reassignment was given or made is subsequently wholly or partially rescinded or
avoided by operation of any law, unless such Lender Finance Party’s action constitutes wilful misconduct or recklessness with knowledge of the probable consequences. 

 

	16.16	Subsequent Encumbrances 

If the Agent receives notice of any subsequent Encumbrance (other than any Permitted Encumbrance) affecting the Vessel or all or any part
of the Insurances, Earnings or Requisition Compensation, the Agent may open a new account in its books for the Borrower. If the Agent does not open a new account, then (unless the Encumbrance is a Permitted Encumbrance or the Agent gives written
notice to the contrary to the Borrower) as from the time of receipt by the Agent of notice of such subsequent Encumbrance, all payments made to the Agent shall be treated as having been credited to a new account of the Borrower and not as having
been applied in reduction of the Lender Indebtedness. 
  

	16.17	Releases 

 If any Lender
Finance Party shall at any time in its discretion release any party from all or any part of any of the Security Documents or from any term, covenant, clause, condition or obligation contained in any of the Security Documents, the liability of any
other party to the Security Documents shall not be varied or diminished. 

  
 83 

			
	16.18	 	Certificates
		
		 	Any certificate or statement signed by an authorised signatory of the Agent purporting to show the amount of the Lender Indebtedness (or any part of the Lender Indebtedness) or
any other amount referred to in any of the Security Documents shall, save for manifest error or on any question of law, be conclusive evidence as against the Borrower of that amount.
		
	16.19	 	Survival of representations and warranties
		
		 	The representations and warranties on the part of the Borrower contained in this Agreement shall survive the execution of this Agreement and the advance of the Loan or any part
thereof.
		
	16.20	 	Counterparts
		
		 	This Agreement may be executed in any number of counterparts each of which shall be original but which shall together constitute the same instrument.
		
	16.21	 	Third Party Rights
		
		 	Notwithstanding the provisions of the Contracts (Rights of Third Parties) Act 1999, no term of this Agreement is enforceable by a person who is not a party to it other than
(a) KEIC in respect of its rights under this Agreement and (b) the Account Bank in respect of its rights under clause 7.5.
		
	16.22	 	Building Contract Disputes
		
		 	The Borrower acknowledges and agrees that its obligations under this Agreement are independent from the Building Contract and that the performance of these obligations shall in
no event be affected by any dispute whatsoever that may arise between the Builder and the Borrower in relation to the Building Contract or in any other respect.
		
	16.23	 	Confidentiality
		
		 	At all times during the Facility Period, the Borrower shall keep confidential any Confidential Information (as defined below) relating to the Relevant Documents (other than the
Project Documents) and each of the Lender Finance Parties shall keep confidential any Confidential Information (as defined below) relating to the Relevant Documents, and none of the Borrower or the Lender Finance Parties shall, without the prior
written consent of the other(s):
		
	 16.23.1
	 	issue any press release or make any other public announcement or statement in relation to the transactions evidenced by this Agreement and the other Relevant Documents;
or
		
	 16.23.2
	 	disclose to any other person (i) any information or document relating to the Angola LNG Project in general, including but not limited to, technical and schedule
requirements, and progress and status of the Angola LNG Project; (ii) financial details of this Agreement or any other Relevant Document or the transactions contemplated by this Agreement or any other Relevant Document or any other agreement
after the date of this Agreement by the Borrower or the Lender Finance Parties in connection with this Agreement or any other Relevant Document or (iii) any information provided pursuant to any of the Relevant Documents; or
		
	16.23.3	 	release copies of drafts of this Agreement or any other Relevant Document which disclose or reveal the identity of the parties (or any of them),
		
		 	the information contemplated by clauses 16.23.1 to 16.23.3 above being “Confidential Information”.

  
 84 

 Provided that notwithstanding the foregoing provisions of this clause 16.22 the parties
shall be entitled, without any such consent, to disclose such Confidential Information: 
  

	 	(a)	if the same is already known to the receiving person at the time of disclosure as shown by the receiving person’s files and records immediately prior to that
disclosure or is developed by the receiving person independently of such disclosure; or 

  

	 	(b)	in connection with any proceedings arising out of or in connection with this Agreement or any of the other Relevant Documents; or 

 

	 	(c)	if required to do so by an order of a court of competent jurisdiction whether in pursuance of any procedure for discovery of documents or otherwise; or

  

	 	(d)	pursuant to any applicable law, stock exchange regulations or by a governmental order, decree, regulation or rule, provided however that a party which has received
Confidential Information which they are obliged to disclose as contemplated by this clause (d) shall use reasonable efforts to inform the person who provided them with the Confidential Information prior to making such disclosure; or

  

	 	(e)	to any fiscal, monetary, tax, governmental or other competent authority; or 

 

	 	(f)	to the auditors, legal or professional or insurance advisors, underwriters or brokers of the Borrower or the relevant Lender Finance Party, who (A) shall have a
need to have such knowledge of the same in connection with carrying out work related to the transaction contemplated by this Agreement and the other Relevant Documents and (B) shall be advised of the confidential nature of any such information
supplied to them and shall be instructed to maintain the confidentiality of any information supplied to them; or 

  

	 	(g)	in any manner contemplated by any of the Relevant Documents; or 

  

	 	(h)	if the same is in the public domain or shall become publicly known otherwise than as a result of a breach by such party or by the receiving person or any other person
to whom disclosure is made of this clause 16.23.1; or 

  

	 	(i)	if the same is acquired independently from a third party without breach of that third party’s obligations of confidentiality; or 

 

	 	(j)	in the case of the Borrower, to any Borrower Shareholder or Sponsor or the Time Charterer, to the extent the Borrower reasonably believes necessary for the purpose of
the Time Charterer to perform, fulfil its obligations or exercise its rights in accordance with the terms of the Time Charterer,Charter, or to any member of the Time Charterer, any of such member’s affiliates, and their
respective directors, officers, employees or contractors, in each case to the extent the Borrower reasonably believes necessary for the performance of the Security Documents and/or the Project Documents and in the case of the Lender Finance
Parties, to any member of their respective groups or any potential transferee, assignee, successor, any rating agency or any financial institutions, special purpose securitisation vehicles and their managements, all investors, agents, arrangers,
dealers who are or might wish to be involved in securitisation schemes, hedging agreements, participation or other risk transfer agreements (or any director, officer or employee, of the foregoing), provided that in each case the Borrower or
the Lender Finance Party shall procure that the party to whom such disclosure is made shall comply with the requirements of this clause and provided further that the Lender Finance Parties shall not disclose any information regarding the Angola LNG
Project to any of the foregoing persons except to a member of their respective groups, any potential transferee, assignee, successor or financial institution on a need-to-know basis and solely for carrying out the purpose of and exercising their
rights under this Agreement and the other Security Documents; or 

  
 85 

	 	(k)	to KEIC, 

  

	 	    	provided that if the Confidential Information is provided by a party on the basis that it is to be kept confidential, but the party providing the information discloses
it to another person on a non-confidential basis, then the receiving party or parties shall no longer be obliged to treat such information as confidential. 

 

	16.23.4	The Borrower and the Lender Finance Parties shall be responsible for ensuring that where Confidential Information is disclosed to persons under clause 16.23.3 such
persons shall keep the information confidential in accordance with and subject to this clause 16.23. 

  

	17	Law and Jurisdiction 

  

	17.1	     Governing law 

 This Agreement shall in all respects be governed by and interpreted in accordance with English law. 
  

	17.2	    Jurisdiction 

 For the exclusive benefit of the Lender Finance Parties, the parties to this Agreement irrevocably agree that the English courts are to have jurisdiction to settle any disputes which may arise out of or
in connection with this Agreement and that any legal actions or proceedings may be brought in those courts. The Borrower irrevocably waives any objection which it may now or in the future have to the laying of the venue of any legal actions or
proceedings in any court referred to in this clause 17.2, and any claim that such legal actions or proceedings have been brought in an inconvenient or inappropriate forum. The Borrower irrevocably and unconditionally submits to the jurisdiction of
such courts and shall within five (5) Business Days of the date hereof irrevocably designate, appoint and empower an agent to receive for it and on its behalf, service of process issued out of the English courts in any such legal actions or
proceedings and shall provide the Facility Agent with details of such agent. The submission to such jurisdiction shall not (and shall not be construed so as to) limit the right of any of the Lender Finance Parties to take legal actions or
proceedings against the Borrower in the courts of any other competent jurisdiction nor shall the taking of legal actions or proceedings in any one or more jurisdictions preclude the taking of legal actions or proceedings in other jurisdiction,
whether concurrently or not. 
 The parties further agree that only the courts of England and not those of any other state or
jurisdiction shall have jurisdiction to determine any claim which the Borrower may have against any of the Lender Finance Parties arising out of or in connection with this Agreement. 
 IN WITNESS of which the parties to this Agreement have executed this Agreement the day and year first before written. 

  
 86 

 Schedule 1 
 Part I: The Lenders, the Commitments and the Proportionate Shares 
 Part
1: the Lenders 
  

							
	 The Lenders
	  	 Contact Details
	  	 Commitments

	  	  	 Buyer Credit
	  	 Commercial Loan

		  	 For commercial matters:
 CIB - Transportation Group
 16 rue de Hanovre

75078 Paris Cedex 02 - France
 Fax no. +33 1 42 98 43 55
	  		  	
				
		  	 Attention: Shipping Finance Alice
 Renaudin Durand-Ruel
	  		  	
				
		  	 For Security Trustee matters:
 CIB - Transportation Group
 16 rue de Hanovre

75078 Paris Cedex 02 - France
 Fax no. +33 1 42 98 43 55
	  		  	
				
		  	Attention: Shipping Asset Monitoring Jean-Marc Morant	  		  	
				
	 BNP Paribas S.A.
	  	 For Agency matters:

CIB -Agency - European Group

21 Place du Marche Saint Honore

75031 Paris Cedex 01 - CHA02A1
 Fax no. +33 1 42 98 43 17
  

Attention: European Group
 Claire-Marie
Rochette
  
 For KEIC Agent matters:

BNP Paribas S.A., Seoul Branch

24/F, Taepyeongno 2-ga, Jung-gu
 Seoul 100-767
Korea
 Fax no. 82 2 757 2530
  

Attention: Jae Seung / Myung Shim Kwon
	  	$15,400,000	  	$19,600,000

  
 87 

							
	 The Lenders
	  	 Contact Details
	  	 Commitments

	  	  	 Buyer Credit
	  	 Commercial Loan

		  	 For administration matters:
 9 Quai, du President Paul Doumer 92920 Paris La Défence Cédex France
	  		  	
				
	Calyon	  	 Fax no: +33 141 89 19 34 Attention: Middle Office/Shipping/ Ms Marie-Claire Vanderperre/ M. Godet-Couery

 
 For credit matters:
 Broadwalk House
 5 Appold Street
 London
 EC2A 2DA
  

Fax no: +44 207 214 6689 Attention: Thibaud Escoffier/Jerome Duval
	  	$ 15,400,000	  	$19,600,000
				
	DnB NOR Bank ASA	  	 For administrative matters:
 20 St. Dunstan’s Hill
 London
 EC3R 8HY
  
 Fax no. +44 207 283
4430 Attention: Loans Administration
 Mr Renato Mariano 
  

For credit matters:
 20 St. Dunstan’s
Hill
 London
 EC3R 8HY

 
 Fax no. +44 207 626 5956 Attention: Omar Sekkat and David Grant
	  	$15,400,000	  	$19,600,000
				
		  	 For operational matters:
 OPER / CAF / DMT6
 17 Cours Valmy
 Paris La Defense 7
	  		  	
				
		  	Fax no. +331 46 92 45 98 Attention: Viengkham LAY and Chantal Alcaras	  		  	
				
	Société Générale,	  	 For credit matters:

SG House
 41 Tower Hill

London
 EC3N 4SG

 
 Fax no. +44 207 667 2499 Attention: Gareth-Lon Williams

 
 Copy to: Pierre Baud and Laurence
	  	$15,400,000	  	$19,600,000
				
		  	 Alloiteau

OPER/CAF/AFI
 17 Cours Valmy

Paris La Défence 7
  
 Fax no. 01.46.92.46.22
  
 Copy
to: Guylaine Labidurie OPER/CAF.EXT
  
 Fax no.
01.46.92.45.97
	  		  	

  
 88 

							
	 The Lenders
	  	 Contact Details
	  	Commitments
	  	  	Buyer Credit	  	Commercial Loan
		  	 For operational matters:
 99 Queen Victoria Street
 London
 EC4V 4EH
	  		  	
				
		  	Fax no. +44 207 786 1569 Attention: David Griffiths/Jo Dunnage	  		  	
				
		  	 For credit matters:

99 Queen Victoria Street
 London

EC4V 4EH
	  		  	
				
	Sumitomo Mitsui Banking Corporation, Brussels Branch	  	 Fax no. +44 207 786 101 Attention: Robert Taylor/Cyrille Martin

 
 Copy to: Guillaume Dufour/Touf-itri Akdime

20 rue de la ville l’evêque 75008 Paris
	  	$15,400,000	  	$19,600,000
				
		  	Fax no. +33 1 44 71 40 50	  		  	
				
		  	 Copy to: Françoise Bouchat/Nadine Boudart
 Avenue des Arts 58,
 Box 18
 1000 Brussels
 Belgium
	  		  	
				
		  	Fax no. +32 2 502 07 80	  		  	

  
 89 

							
	 The Lenders
	  	 Contact Details
	  	 Commitments

	  	  	 Buyer Credit
	  	 Commercial Loan

		  	 For administrative matters:
 12-15 Finsbury Circus
 London
 EC2M 7BT
	  		  	
				
		  	Fax no. +44 207 577 1559 Attention: Daniel Bryan	  		  	
				
	The Bank of Tokyo - Mitsubishi UFJ, Ltd.	  	 For credit matters;

12-15 Finsbury Circus
 London

EC2M 7BT
	  	$15,400,000	  	$19,600,000
				
		  	 Fax no. +44 207 577 1755

Attention: Grahame Hunt
	  		  	
				
		  		  	$92,400,000	  	$117,600,000

  
 90 

 Part 2: 
 the Swap Providers 
  

			
	 The Lenders
	  	 Contact Details

		  	For commercial matters:
		  	CIB—Transportation Group
		  	16 rue de Hanovre
		  	75078 Paris Cedex 02—France
		  	Fax no. +33 1 42 98 43 55
		
		  	Attention: Shipping Finance
		  	Alice Renaudin Durand-Ruel
		
		  	For Security Trustee matters:
		  	CIB—Transportation Group
		  	16 rue de Hanovre
		  	75078 Paris Cedex 02—France
		  	Fax no. +33 1 42 98 43 55
		
		  	Attention: Shipping Asset Monitoring
		  	Jean-Marc Morant
		
	BNP Paribas S.A.	  	For Agency matters:
		  	CIB—Agency—European Group
		  	21 Place du Marche Saint Honore
		  	75031 Paris Cedex 01—CHA02A1
		  	Fax no. +33 1 42 98 43 17
		
		  	Attention: European Group
		  	Claire-Marie Rochette
		
		  	For KEIC Agent matters:
		  	BNP Paribas S.A., Seoul Branch
		  	24/F, Taepyeongno 2-ga, Jung-gu
		  	Seoul 100-767 Korea
		  	Fax no. 82 2 757 2530
		
		  	Attention: Jae Seung / Myung Shim
		  	Kwon

  
 91 

			
	 The Lenders
	  	 Contact Details

		  	For administration matters:
		  	9 Quai, du President Paul Doumer
		  	92920 Paris La Défence Cédex
		  	France
		
		  	Fax no: +33 141 89 19 34
		  	Attention: Middle Office/Shipping/
		  	Ms Marie-Claire Vanderperre/
		  	M. Godet-Couery
	Calyon	  	
		  	For credit matters:
		  	Broadwalk House
		  	5 Appold Street
		  	London
		  	EC2A 2DA
		
		  	Fax no: +44 207 214 6689
		  	Attention: Thibaud Escoffier/Jerome
		  	Duval
		
		  	For administrative matters:
		  	20 St. Dunstan’s Hill
		  	London
		  	EC3R 8HY
		
		  	Fax no. +44 207 283 4430
		  	Attention: Loans Administration
		  	Mr Renato Mariano
	DnB NOR Bank ASA	  	
		  	For credit matters:
		  	20 St. Dunstan’s Hill
		  	London
		  	EC3R 8HY
		
		  	Fax no. +44 207 626 5956
		  	Attention: Omar Sekkat and David
		  	Grant
		
		  	For operational matters
		  	OPER / CAF / DMT6
		  	17 Cours Valmy
		  	Paris La Defense 7
		
		  	Fax no. +331 46 92 45 98
		  	Attention: Viengkham LAY and
		  	Chantal Alcaras
		
	Société Générale,	  	For credit matters
		  	London
		
		  	Fax no. +44 207 667 2499
		  	Attention: Gareth-Lon Williams
		
		  	Copy to: Pierre Baud and Laurence
		  	Alloiteau
		  	OPER/CAF/AFI
		  	17 Cours Valmy
		  	Paris La Défence 7
		
		  	Fax no. 01.46.92.46.22
		
		  	Copy to: Guylaine Labidurie OPER/CAF.EXT
		
		  	Fax no. 01.46.92.45.97

  
 92 

			
	 The Lenders
	  	 Contact Details

	SMBC Capital Markets, Inc.	  	 277 Park Avenue
 Fifth
Floor
 New York
 10172

USA
  
 Attention: President
 Fax no. (212) 224-4948

		
	 The Bank of Tokyo -
 Mitsubishi UFJ, Ltd.
	  	 For administrative matters:
 12-15 Finsbury Circus
 London
 EC2M 7BT
  
 Fax no. +44 207 577
1559
 Attention: Daniel Bryan
  

For credit matters;
 12-15 Finsbury
Circus
 London
 EC2M 7BT

 
 Fax no. +44 207 577 1755
 Attention: Grahame Hunt

  
 93 

 Schedule 2 
 The Vessel 
  

							
	Owner	 	Hull No	 	Flag	 	Vessel Type
	 MiNT IV LNG, Ltd
	 	1813 at Samsung	 	Bahamas	 	160,000 cubic meter single
		 	Heavy Industries Co.	 		 	screw electric motor driven
		 	Ltd.	 		 	liquefied natural gas carrier

  
 94 

 Schedule 3 
 Documents and evidence required as conditions precedent 
 (referred to in
clause 3.1) 
 Part I1: Commitment and first Drawing 

 

	(a)	Constitutional documents 

  

	 	(i)	copies, certified by an officer of each Security Partythe Borrower, NYK LNG and Teekay as true, complete and up to date copies of all
documents which contain or establish the constitution of that Security Partyit including the Articles of Incorporation; or 

  

	 	(ii)	with respect to Mitsui and NYK, in lieu of the document described in clause (a)(i) above, a certified copy of the current Commercial Register (genzai jiko
zenbu shomeisho) of Mitsui and NYK issued by the Tokyo Legal Affairs Bureau no earlier than 10 days prior to the date of this Agreement. 

  

	(b)	Corporate authorisationsauthorizations 

  

	 	(i)	copies of resolutions of the directors and/or such other corporate approvals or authorisations and, to the extent required to obtain any opinion set out in this
Schedule 3, Part 1, the shareholders of each Security Partythe Borrower, NYK LNG and Teekay approving such of the Project Documents (with respect to the Borrower only) and the Security Documents to which it is, or is
to be, party and authorising the signature, delivery and performance of its obligations thereunder, certified (in a certificate dated no earlier than 10 Business Days prior to the date of this Agreement) by an officer of it as:

  

	 	1.	(i) being true and correct; 

  

	 	2.	(ii) being duly passed by the directors or such other persons as permitted by the organisational documents of such Security
Partyit and (if necessary) shareholders of such Security Partyit; 

  

	 	3.	(iii) not having been amended, modified or revoked; and 

  

	 	4.	(iv) being in full force and effect, 

 together with originals or certified copies of any powers of attorney issued by it pursuant to such resolutions; or 
  

	 	(ii)	with respect to Mitsui and NYK, in lieu of the document described in clause (b)(i) above: (1) a power of attorney, executed using the registered seal of the
president or representative director of Mitsui or NYK, authorizing the signatory or signatories of the Security Documents to which Mitsui or NYK is a party to execute such documents on behalf of Mitsui or NYK; and (2) a seal certificate
(inkan shoumei), issued by the Tokyo Legal Affairs Bureau no earlier than 10 days prior to the date of this Agreement, in respect of the registered seal used to execute the power of attorney described in clause (b)(ii)(2).

  

	(c)	Specimen signatures 

copies of the signatures of the persons who have been authorised on behalf of each Security Party to sign such of the
Project Security Documents referred to in paragraph (g) of this Schedule 3, part 1 and the Security Document referred to in paragraph (h) of this Schedule 3, part 1 to which such Security Party is, or is to be, party
and to give notices and communications, including notices of drawing, under or in connection with the Security Documents, certified (in a certificate dated no earlier than 10 Business Days prior to the date of this Agreement) by an officer or such
other authorised persons of such Security Party as being the true signatures of such persons; 

  
 95 

	(d)	Certificates of incumbency 

a list of directors and officers of the Borrower, the Borrower Shareholders and the Sponsors specifying the names
and positions of such persons, certified (in a certificate dated no earlier than 10 Business Days prior to the date of this Agreement) by an officer or such other authorised person of it to be true, complete and up to date; 

 

	(e)	Time Charterer’s consents and approvals 

 evidence in a form and substance acceptable to the Agent that the Time Charterer shall have consented (so far as may be necessary) to the execution of the Mortgage, the Deed of Covenants, the Deed of
Assignment of Contracts and the Deed of Assignment of Building Contract and Refund Guarantee and other necessary documents hereunder in accordance with the Time Charter; 

 

	(f)	Certified Project Documents 

 a copy, certified (in a certificate dated no earlier than 5 Business Days prior to the date of this Agreement) as a true and complete copy by an officer of the Borrower of each of the Project Documents
(other than the Management Agreement) and the Sub Management Agreement each duly executed and in a form and substance acceptable in all respects to the Agent together with the original executed copies of the Refund Guarantee; 

 

	(g)	Security Documents and Fee Letters 

 the Swap Agreements, any other Credit Support Documents, the Deed of Assignment of Contracts, the Assignment, the Deed of Assignment of Building Contract and Refund Guarantee, the Account Charge, the
Sponsors’ Undertaking, the Arrangement Fee Letter, the Agency Fee Letter, the Account Bank Fee Letter, the Documentation Agency Fee Letter and the Swap Margin Side Letter each duly executed; 

 

	(h)	Notices of assignment and acknowledgements 

 the Building Contract Assignment Consent and Acknowledgement, the Refund Guarantee Assignment Consent and Acknowledgement, and the Supervision Agreement Consent and Acknowledgement, the
Management Agreement Consent and Acknowledgement and the Sub Management Agreement Consent and Acknowledgement duly executed and bearing formal date stamps and originals of duly executed notices of assignment together with original duly
executed acknowledgements thereof (to be delivered on the first Drawdown Date) required by the terms of the Deed of Assignment of Contracts and the Deed of Assignment of Building Contract and Refund Guarantee respectively in the forms prescribed by
such Security Documents; 
  

	(i)	Share PledgesCharges 

 (i) the Share PledgesCharges duly executed by all parties thereto (other than the Security Trustee) and all requirements thereunder fully satisfied including, without limitation,
the delivery of the Borrower’s share certificates and all irrevocable proxies to the Security Trustee; 
  

	(j)	Accounts 

 evidence that
the Accounts have been opened; 

  
 96 

	(k)	Bahamas opinion 

 opinions
(addressed to the Agent and KEIC) of the Agent’s special legal advisers in the Bahamas to the Agent prior to the first Drawing in form and substance satisfactory to the Lenders to be delivered on the first Drawdown Date; 

 

	(l)	Delaware opinion 

 opinion
(addressed to the Agent and KEIC) of special legal advisers in the State of Delaware in relation to (a) the due authorisation, execution, delivery and performance of the Time Charter, the Tripartite Agreement, the Angolanisation Agreement, the
Project Co-ordination Agreement and the Depot Spares Sharing Agreement by the Time Charterer and such documents constituting the legal, valid and binding obligations of the Time Charterer, (b) the execution, delivery and
performance of the Time Charter, the Tripartite Agreement, the Angolanisation Agreement, the Project Co-ordination Agreement and the Depot Spares Sharing Agreement by the Time Charterer not conflicting with Delaware law and (c) the execution,
delivery and performance of the Time Charter by the Time Charterer not conflicting with its constitutional documents to be received prior to the first Drawing in form and substance satisfactory to the Lenders to be delivered on the first Drawdown
Date; 
  

	(m)	Korean opinion 

 opinions
(addressed to the Agent and KEIC) of Kim & Chang special legal advisers in Korea to the Agent and KEIC Agent prior to the first Drawing in form and substance satisfactory to the Lenders to be delivered on the first Drawdown Date;

  

	(n)	Japanese opinion 

opinions (addressed to the Agent and KEIC) of Nishimura & Asahi special legal advisers in Japan to the Agent prior to the first
Drawing in form and substance satisfactory to the Lenders to be delivered on the first Drawdown Date; 
  

	(o)	Marshall Islands opinion 

opinions (addressed to the Agent and KEIC) of the Agent’s special legal advisors in the Marshall Islands to the Agent prior to the
first Drawing in form and substance satisfactory to the Lenders to be delivered on the first Drawdown Date; 
  

	(p)	English opinion 

 opinion
of Norton Rose LLP special legal advisors in England to the Agent prior to the first Drawing in form and substance satisfactory to KEIC to be delivered on the first Drawdown Date; 

 

	(q)	Further opinions/report 

(ii) an opinion from Norton Rose as to the legality, validity and enforceability of the Security Documents so far as they are governed by
the laws of England and Wales and in a form and substance acceptable in all respects to the Agent; 
  

	(r)	Borrower’s process agent 

 a copy, certified as a true copy by the Borrower’s solicitors or other person acceptable to the Agent of a letter from the Borrower’s agent for receipt of service of proceedings referred to in
clause 17.2 accepting its appointment under the said clause and under each of the other Security Documents in which it is or is to be appointed as the Borrower’s agent; 

 

	(s)	Process agent 

 a copy,
certified as a true copy by the Borrower’s solicitors or other person acceptable to the Agent of a letter from the Sponsors’ and any other Security Party’s agent for receipt of service of proceedings accepting its appointment under
each of the relevant Security Documents in which it is or is to be appointed as the Sponsors’ or such Security Party’s agent; 

  
 97 

	(t)	Drawdown Notice 

 the
Drawdown Notice in respect of the first Drawing duly executed and delivered in accordance with clause 2 of this Agreement; 
  

	(u)	Minimum Borrower Shareholders’ Equity / Additional Shareholders’ Equity 

receipt of the Relevant Amount of the Minimum Borrower Shareholders’ Equity and/or Additional Shareholders’ Equity by the
Borrower or the Agent in accordance with clause 2.3.7 and, insofar as such Relevant Amount is Indebtedness of the Borrower, any subordination agreement required by the Agent in form and substance satisfactory to the Agent (acting on the instructions
of all Lenders) in connection therewith; 
  

	(v)	Minimum Credit Rating 

evidence from either Standard and Poors or Fitch on or after the date falling 5 Business Days prior to the Drawdown Date that the Refund
Guarantor still maintains the required Minimum Credit Rating; 
  

	(w)	Ownership 

 evidence
satisfactory in all respects to the Agent that the Sponsors are, directly or indirectly the legal and beneficial owner of all of the issued share capital of the Borrower, (whether ordinary, preferential or other class of share capital (including,
without limitation, subordinated debt)) other than as permitted pursuant to clause 9.2.17; 
  

	(x)	Fees and commissions 

evidence of payment or evidence that payment will be made from the first Drawing of any fees and commissions due and payable from the
Borrower to the Agent, the Security Trustee, Calyon or the Account Banks pursuant to clause 7 or any other provision of the Security Documents; 
  

	(y)	KEIC Buyer Credit Policy 

in respect of the first Drawing the prior receipt by the Agent of an original counterpart of the relevant KEIC Buyer Credit Policy, duly
executed by KEIC (together with a copy of the signing authority of the relevant officer of KEIC) and certified copy of the KEIC Acceptance Letter, such KEIC Buyer Credit Policy to be in full force and effect; 

 

	(z)	Project Co-ordination Agreement 

 evidence that the Project Co-ordination Agreement has been executed in a form and substance acceptable in all respects to the Agent acting on the instructions of all Lenders; 

 

	(aa)	KYC documentation 

receipt by each Lender of “know-your-client” documentation satisfactory to it; and 

 

	(bb)	Accounts 

 the certified
true and complete copies of the most recent audited annual financial statements of each Sponsor and the unaudited semi-annual accounts of the Borrower for the period ending on 31 December 2007. 

  
 98 

 Part 2 
 Contract Instalment Advances 
  

	(a)	Invoice 

 a certified copy
of the invoice in respect of which payment is due to the Builder from the Borrower; 
  

	(b)	Fees and commissions 

(other than in respect of a Contract Instalment Advance which is the first Drawing) evidence of payment or evidence that payment will be
made from the Contract Instalment Advance of any fees and commissions due from the Borrower to the Agent, Calyon, the Security Trustee or the Account Bank pursuant to the terms of clause 7 or any other provision of the Security Documents;

  

	(c)	Conditions precedent 

confirmation from the Borrower or its legal advisers that the conditions precedent set out in Part 1 to Schedule 3 remain satisfied and to
the extent necessary are satisfied and confirmation from the Borrower that no further consents and approvals are required; 
  

	(d)	Minimum Borrower Shareholders’ Equity / Additional Shareholders’ Equity 

receipt of the Relevant Amount of the Minimum Borrower Shareholders’ Equity and/or Additional Shareholders’ Equity by the Agent
in accordance with clauses 2.3.7 and 2.9 and any subordination agreement required by the Agent in connection therewith; 
  

	(e)	Drawdown Notice 

 the
Drawdown Notice in respect of the relevant Contract Instalment Advance duly executed and delivered in accordance with clause 2 of this Agreement; 
  

	(f)	No claim 

 evidence
satisfactory to the Agent in the form of a declaration of warranty from the Builder that the Builder (and any other party who may have a claim pursuant to the Building Contract) has no claims against the Vessel or the Borrower; 

 

	(g)	No variations to Building Contract 

 confirmation from the Borrower that save as permitted by this Agreement there have been no amendments or variations agreed to the Building Contract that have not been agreed by the Agent (acting on the
instructions of the Majority Lenders) and that no action has been taken by either the Builder or the Borrower which might in any way render the Building Contract inoperative or unenforceable, in whole or in any part; and 

 

	(h)	No encumbrance 

confirmation from the Borrower that there is no Encumbrance (other than a Permitted Encumbrance) of any kind created or permitted by any
person on or relating to the Building Contract or in relation to the Vessel. 

  
 99 

 Part 3 
 Delivery Date Advance 
  

	(a)	Export Licence(s) 

 a
copy, certified as a true and complete copy by an officer of the Borrower of all consents, authorisations, licences and approvals required by the Borrower and the Builder (if any) in connection with the export by the Builder of the Vessel;

  

	(b)	Vessel conditions 

evidence that the Vessel: 
  

	 	(i)	Registration and Encumbrances 

 is or simultaneously with the Delivery of the Vessel shall be registered in the name of the Borrower through the Bahamas Registry under the laws and flag of the Bahamas and confirmation from the Borrower
that the Vessel and its Earnings, Insurances and Requisition Compensation (as defined in the Deed of Covenants) are free of Encumbrances (other than Permitted Encumbrances); 

 

	 	(ii)	Classification 

 has the
classification referred to in clause 9.6.3(b) free of all overdue requirements and recommendations of the Classification Society; 
  

	 	(iii)	Insurance 

 is insured in
accordance with the provisions of the Security Documents and all requirements of the Security Documents in respect of such insurance have been complied with (including without limitation, (A) confirmation from the protection and indemnity
association or other insurer with which the Vessel is, or is to be, entered for insurance or insured against protection and indemnity risks (including oil pollution risks) that any necessary declarations required by the association or insurer for
the removal of any oil pollution exclusion have been made and that any such exclusion does not apply to the Vessel and (B) receipt by the Agent of pro-forma letters of undertaking from the Approved Brokers (as defined in the relevant
Deed of Covenant)approved brokers in such form as the Agent may reasonably require); and 
  

	 	(iv)	Delivery under Time Charter 

 has been or on the Delivery Date will be delivered to, and accepted by, the Time Charterer for service under the Time Charter; 

 

	(c)	Deletion 

 evidence that
any prior registration of the Vessel in the name of the Builder has been cancelled (or confirmation from the Builder that there was no such prior registration) and that no Encumbrances other than Permitted Encumbrances are registered against the
Vessel on such register; 
  

	(d)	Security and delivery documents 

 certified true copies of the Management Agreement, the Sub-Management Agreement, the Builder’s Certificate and the Protocol of Delivery and Acceptance and originals of the Mortgage, the Deed of
Covenants, the Assignment and, the Manager’s Undertaking, the Sub-Manager’s Undertaking and the Management Agreement Consent and Acknowledgment each duly executed; 

  
 100

	(e)	Borrower’s further corporate authorisations 

 copies of the resolutions of the Borrower’s directors and (if necessary) shareholders evidencing authorisation of the acceptance of the delivery of the Vessel and authorisation and approval of the
Mortgage, the Deed of Covenants and the transactions contemplated therein and any other documents issued or to be issued pursuant thereto and authorising its appropriate officer or other representative to execute the same on its behalf certified in
the manner referred to in paragraph (b) of Part 1 of this Schedule (or other evidence of such authorisation, approval and/or ratification) and any power of attorney issued pursuant to the said resolutions (such resolutions and power of attorney
to be notarised (and, to the extent required by applicable Law, apostiled) and in a form and substance acceptable in all respects to the Agent); 
  

	(f)	Mortgage registration 

evidence that the Mortgage has been registered against the Vessel through the Bahamas Registry under the laws and flag of the Bahamas;

  

	(g)	Notices of assignment and acknowledgements 

 originals of duly executed notices of assignment required by the terms of the Deed of Covenants and the Assignment together with original duly executed acknowledgements thereof required by the terms of
such Security Documents and in the form(s) prescribed by such Security Documents and, in the case of the Assignment; 
  

	(h)	Insurance opinion 

 an
opinion from Bankserve, or such other insurance consultants as the Agent may instruct, on the insurances effected or to be effected in respect of the Vessel upon and following the Delivery Date in form and substance satisfactory to the Lenders;

  

	(i)	Bahamas opinion 

 an
opinion of the Agent’s special legal advisers in the Bahamas to the Agent in form and substance satisfactory to the Lenders; 
  

	(j)	Korean opinion 

 an
opinion of Kim & Chang special legal advisers in Korea to the KEIC Agent and the Agent in form and substance satisfactory to the Lenders; 
  

	(k)	Further opinions 

 any
such further opinion as may reasonably be required by the Agent to evidence the legality, validity and/or enforceability of the obligations of the Borrower and/or any Security Party under this Agreement, each of the other Security Documents and each
of the Project Documents to which it is a party; 
  

	(l)	Process agent 

 a copy,
certified as a true copy by the Borrower’s solicitors or other person acceptable to the Agent of a letter from the Borrower’s agent for receipt of service of proceedings referred to in clause 17.2 accepting its appointment under the said
clause and under each of the Mortgage, the Deed of Covenants, the Assignment and also in respect of the relevant Manager’s Undertaking in which it is or is to be appointed as agent; 

 

	(m)	Fees and commission 

evidence that the fees and commissions due under clause 7 have been paid in full (or upon drawdown of the Delivery Date Advance will have
been paid); 

  
 101

	(n)	Payment of Contract Price 

evidence from the Builder that the Contract Price has been (or upon drawdown of the relevant Delivery Date Advance will have been) paid in
full and a certified copy of the invoice in respect of the payment due to the Builder from the Borrower on the Delivery Date; 
  

	(o)	Drawdown Notice 

 the
Drawdown Notice in respect of the relevant Delivery Date Advance duly executed and delivered to the Agent in accordance with clause 2 of this Agreement; 
  

	(p)	Protocol of Delivery and Acceptance 

 copies, certified as true copies by a director or officer of the Borrower, of the Protocol of Delivery and Acceptance and any other documents issued by the Builder in connection with the construction and
delivery of the Vessel as the Builder shall be obliged to provide pursuant to the Building Contract; 
  

	(q)	ISM compliance 

 evidence
that the Operator has applied to the relevant Regulatory Agency for a DOC for itself and an SMC for the Vessel to be issued pursuant to the Code within any time limit required or recommended by such Regulatory Agency; 

 

	(r)	Minimum Borrower Shareholders’ Equity / Additional Shareholders’ Equity 

receipt of the Relevant Amount of the Minimum Borrower Shareholders’ Equity and/or Additional Shareholders’ Equity by the Agent
in accordance with sub-clauses 2.3.7 and 2.9 and any subordination agreement required by the Agent in connection therewith; and 
  

	(s)	Conditions precedent 

confirmation from the Borrower or their legal advisers that the conditions precedent set out in Parts 1 and 2 of Schedule 3 remain
satisfied and to the extent necessary are satisfied and confirmation from the Borrower that no further consents and approvals are required. 

  
 102

 Schedule 4 
 Form of Transfer Certificate 
  

	To:	BNP Paribas S.A. as agent (the “Agent”) 

 TRANSFER CERTIFICATE 
 This transfer certificate relates to a facility agreement (as the
same may be from time to time amended, varied, novated or supplemented, the “Loan Agreement”) dated 2008 whereby a credit facility of up to $210,000,000 was made available to Mint LNG IV, Ltd (the “Borrower”) by a
group of banks on whose behalf the Agent acts as agent and security trustee. 
  

	1	Terms defined in the Loan Agreement shall, subject to any contrary indication, have the same meanings herein. The terms “Lender” and “Transferee”
are defined in the schedule to this transfer certificate. 

  

	2	The Lender (i) confirms that the details in the Schedule hereto next to the heading “Commitment” accurately summarises its Commitment in the Loan
Agreement and (ii) requests the Transferee to accept and procure the transfer to the Transferee of the portion of such Commitment specified in the Schedule hereto next to the heading “Portion Transferred” by counter-signing and
delivering the Transfer Certificate to the Agent at its address for the service of communications specified in the Loan Agreement. 

  

	3	The Transferee requests the Agent to accept this Transfer Certificate as being delivered to the Agent pursuant to and for the purposes of clause 12.4 of the Loan
Agreement so as to take effect in accordance with the terms thereof on the Transfer Date or on such later date as may be determined in accordance with the terms thereof. 

 

	4	The Transferee confirms that it has received a copy of the Loan Agreement together with such other information as it has required in connection with this transaction
and that it has not relied and will not in the future rely on the Lender or any other party to the Loan Agreement to check or enquire on its behalf into the legality, validity, effectiveness, adequacy, accuracy or completeness of any such
information and further agrees that it has not relied and will not rely on the Lender or any other party to the Loan Agreement to access or keep under review on its behalf the financial condition, creditworthiness, condition, affairs, status or
nature of the Borrower or any other party to the Loan Agreement. 

  

	5	Execution of this Transfer Certificate by the Transferee constitutes its representation to the Transferor and all other parties to the Loan Agreement that it has power
to become a party to the Loan Agreement as a Lender on the terms herein and therein set out and has taken all steps to authorise execution and delivery of this Transfer Certificate. 

 

	6	The Transferee undertakes with the Lender and each of the other parties to the Loan Agreement that it will perform in accordance with their terms all those obligations
which by the terms of the Loan Agreement will be assumed by it after delivery of this Transfer Certificate to the Agent and satisfaction of the conditions (if any) subject to which the Transfer Certificate is expressed to take effect.

  

	7	The Lender makes no representation or warranty and assumes no responsibility with respect to the legality, validity, effectiveness, adequacy or enforceability of the
Loan Agreement or any document relating thereto and assumes no responsibility for the financial condition of the Borrower or for the performance and observance by the Borrower of any of its obligations under the Loan Agreement or any document
relating thereto and any and all such conditions and warranties, whether express or implied by law or otherwise, are hereby excluded. 

  
 103

	8	The Lender gives notice that nothing in this transfer certificate or in the Loan Agreement (or any document relating thereto) shall oblige the Lender to (i) accept
a re-transfer from the Transferee of the whole or any part of its rights, benefits and/or obligations under the Loan Agreement transferred pursuant hereto or (ii) support any losses directly or indirectly sustained or incurred by the Transferee
for any reason whatsoever including, without limitation, the non-performance by the Borrower or any other party to the Loan Agreement (or any document relating thereto) of its obligations under any such document. The Transferee acknowledges the
absence of any such obligation as is referred to in (i) or (ii) above. 

  

	9	The Security Trustee’s rights under the Security Documents remain in full force and effect and are not affected by this transfer. 

 

	10	This Transfer Certificate and the rights and obligations of the parties hereunder shall be governed by and interpreted in accordance with English law.

 THE SCHEDULE 
  

	1	Lender: 

  

	2	Transferee: 

  

	3	Transfer Date: 

  

	4	Commitment: 

  

	5	Portion Transferred: 

  

	6	Transferee’s Administration Details: 

  

			
	 [Transferor Bank]
	  	[Transferee Bank]
		
	 By:
	  	By:
		
	 Date:
	  	Date:

 BNP Paribas S.A. 
 As agent for and on behalf of itself, 
 the Borrower and the other Lender Finance Parties in the
presence of:- 

By:                        
         
 Date:
[                                     ] 

  
 104

 Schedule 5 
 Form of Drawdown Notice 
  

	To:	BNP Paribas S.A. 

 Attention: [—] 
 Fax : [—] 

Copy to: [—] 
 Fax: [—] 
 Date [—] 
 Loan facility of up to United States Dollars $210,000,000 in respect of

 Hull No 1813 (the “Vessel”) 
 Loan Agreement dated                             2008

 We refer to the above Loan Agreement and hereby give you notice that we wish to drawdown the following Drawing: 

[a Contract Instalment Advance amounting to $[—];] 

[a Delivery Date Advance amounting to $[—];] 
 [an Ancillary Cost Advance [in respect of the KEIC Insurance Premium for the Vessel] amounting to $[—];] 

Interest Period from [—] to [—]; 

on [—] 20[—] the funds should be credited to [name
and number of account] with [details of bank [in New York City]]. 
 [The Vessel is scheduled to be delivered on [—].] 
 We confirm that: 

 

	(i)	no event or circumstance has occurred and is continuing unremedied or unwaived which constitutes a Potential Event of Default; 

 

	(ii)	the representations and warranties contained in clauses [4] of the Loan Agreement are true and correct at the date hereof as if made with respect to the facts and
circumstances existing at the date hereof; 

  

	(iii)	the borrowing of the Loan will be within our corporate powers, has been validly authorised by appropriate corporate action and will not cause any limit on our
borrowings (whether imposed by statute, regulation, agreement or otherwise) to be exceeded; [and] 

  

	(iv)	there has been no material adverse change in our financial position from that set forth in the latest financial statements delivered to you under clause 9.1.5 of the
Loan Agreement. [;and] 

  

	(v)	[this Ancillary Cost Advance will not, when aggregated with all Ancillary Cost Advances previously advanced to us, equal a sum in excess of $36,000,000.]

 Words and expressions defined in the Loan Agreement shall have the same meanings when used herein. 

  
 105

 For and on behalf of 
 MiNT LNG IV, LTD 

			
		
	By	 	 

			
	Name:	 	
	Title:	 	

  
 106

 Schedule 6 
 Calculation of the Mandatory Cost 
  

	1	The Mandatory Cost is an addition to the interest rate to compensate the Lenders for the cost of compliance with (a) the requirements of the Bank of England and/or
the Financial Services Authority (or, in either case, any other authority which replaces all or any of its functions) or (b) the requirements of the European Central Bank. 

 

	2	On the first day of each Interest Period (or as soon as possible thereafter) the Agent shall calculate, as a percentage rate, a rate (the “Additional Cost
Rate”) for each Lender, in accordance with the paragraphs set out below. The Mandatory Cost will be calculated by the Agent as a weighted average of the Lenders’ Additional Cost Rates (weighted in proportion to the percentage
participation of each Lender in the Loan) and will be expressed as a percentage rate per annum. 

  

	3	The Additional Cost Rate for any Lender lending from a Loan Office in a Participating Member State will be the percentage notified by that Lender to the Agent. This
percentage will be certified by that Lender in its notice to the Agent to be its reasonable determination of the cost (expressed as a percentage of that Lender’s participation in all loans made from that Loan Office) of complying with the
minimum reserve requirements of the European Central Bank in respect of loans made from that Loan Office. 

  

	4	The Additional Cost Rate for any Lender lending from a Loan Office in the United Kingdom will be calculated by the Agent as follows: 

E x 0.01 

                    per cent. per
annum. 
     300 
 Where E is the rate of charge payable by a Lender to the Financial Services Authority under the Fees Rules in respect of the relevant financial year of the Financial Services Authority (calculated for
this purpose by the Agent as being the average of the Fee Tariffs applicable to that Lender for that financial year). The resulting figure shall be rounded to four (4) decimal places. 

 

	5	For the purposes of this Schedule: 

  

	 	(a)	“Eligible Liabilities and “Special Deposits” have the meanings given to them from time to time under or pursuant to the Bank of England Act
1998 or (as may be appropriate) by the Bank of England; 

  

	 	(b)	“Loan Office” means the office notified by a Lender to the Agent in writing on or before the date it becomes a Lender as the office through which it
will perform its obligations under the Agreement; 

  

	 	(c)	“Fee Rules” means the rules on periodic fees contained in the FSA Supervision Manual or such other law or regulation as may be in force from time to
time in respect of the payment of fees for the acceptance of deposits; 

  

	 	(d)	“Fee Tariffs” means the fee tariffs specified in the Fees Rules under the activity group A.1 Deposit acceptors (ignoring any minimum fee or zero rated
fee required pursuant to the Fee Rules but taking into account any applicable discount rate); and 

  

	 	(e)	“Participating Member State” means any member state of the European Communities that adopts or has adopted the euro as its lawful currency in
accordance with legislation of the European Union relating to European Monetary Union; 

  

	 	(f)	“Parties” means any party to the Agreement, including its successors in title permitted assigns and permitted transferees; and

  

	 	(g)	“Tariff Base” has the meaning given to it in, and will be calculated in accordance with, the Fees Rules. 

 

	6	If requested by the Agent, each Lender shall, as soon as practicable after publication by the Financial Services Authority, supply to the Agent, the rate of charge
payable by that Lender to the Financial Services Authority pursuant to the Fees Rules in respect of the relevant financial year of the Financial Services Authority (calculated for this purpose by that Lender as being the average of the Fee Tariffs
applicable to that Lender for that financial year). 

  
 107

	7	Each Lender shall supply any information required by the Agent for the purpose of calculating its Additional Cost Rate. In particular, but without limitation, each
Lender Shall supply the following information on or prior to the date on which it becomes a Lender: 

  

	 	(a)	the jurisdiction of its Loan Office; and 

  

	 	(b)	any other information that the Agent may reasonably require for such purpose. 

 Each Lender shall promptly notify the Agent of any change to the information provided by it pursuant to this paragraph. 
  

	8	The percentages of each Lender for the purpose of E above shall be determined by the Agent based upon the information supplied to it pursuant to paragraphs 6 and 7
above and on the assumption that, unless the Lender notifies the Agent to the contrary, each Lender’s obligations in relation to cash ratio deposits and Special Deposits are the same as those of a typical bank from its jurisdiction of
incorporation with a Loan Office in the same jurisdiction as in its Loan Office. 

  

	9	The Agent shall have no liability to any person if such determination results in an Additional Cost Rate which over or under compensates any Lender and shall be
entitled to assume that the information provided by any Lender pursuant to paragraphs 3, 6 and 7 above is true and correct in all respects. 

  

	10	The Agent shall distribute the additional amounts received as a result of the Mandatory Cost to the Lenders on the basis of the Additional Cost Rate for each Lender
based on the information provided by each Lender pursuant to paragraphs 3, 6 and 7 above. 

  

	11	Any determination by the Agent pursuant to this Schedule in relation to a formula, the Mandatory Cost, an Additional Cost Rate or any amount payable to a Lender shall,
in the absence of manifest error, be conclusive and binding on all Parties. 

  

	12	The Agent may from time to time, after consultation with the Borrower and the Lenders determine and notify to all Parties any amendments which are required to be made
to this Schedule in order to comply with any change in law, regulation or any requirements from time to time imposed by the Bank of England, the Financial Services Authority or the European Central Bank (or, in any case, any other authority which
replaces all or any of its functions) and any such determination shall, in the absence of manifest error, be conclusive and binding on all Parties. 

  
 108

 Schedule 7 
 Contract Instalments and Repayment Profile 
 Part A

  

							
	 Installment
	  	 Initiating Event
	  	% of Contract Price	 
	 First
	  	December 29, 2007	  	 	10	% 
	 Second
	  	June 18, 2009	  	 	10	% 
	 Third
	  	The later of the actual date of keel-laying and February 28, 2011	  	 	10	% 
	 Fourth
	  	The later of the actual date of launching and April 30, 2011	  	 	10	% 
	 Final
	  	At Delivery and upon execution of the Acceptance	  	 	60	% 

  
 109

 Part B 

 

															
	 	 	  	Outstanding	 	  	Repayment Amnt	 	  	Repayment %	 
	 	Closing	  	  	 	92,400,000	  	  				  			
	 	1	  	  	 	0.63% 91,080,000	  	  	 	1,320,000	  	  	 	1.429%	  
	 	2	  	  	 	0.64% 89,741,000	  	  	 	1,339,000	  	  	 	1.449%	  
	 	3	  	  	 	0.65% 88,380,000	  	  	 	1,361,000	  	  	 	1.473%	  
	 	4	  	  	 	0.66% 86,999,000	  	  	 	1,381,000	  	  	 	1.495%	  
	 	5	  	  	 	0.67% 85,597,000	  	  	 	1,402,000	  	  	 	1.517%	  
	 	6	  	  	 	0.68% 84,174,000	  	  	 	1,423,000	  	  	 	1.540%	  
	 	7	  	  	 	0.69% 82,729,000	  	  	 	1,445,000	  	  	 	1.564%	  
	 	8	  	  	 	0.70% 81,262,000	  	  	 	1,467,000	  	  	 	1.588%	  
	 	9	  	  	 	0.71% 79,772,000	  	  	 	1,490,000	  	  	 	1.613%	  
	 	10	  	  	 	0.72% 78,260,000	  	  	 	1,512,000	  	  	 	1.636%	  
	 	11	  	  	 	0.73% 76,725,000	  	  	 	1535,000	  	  	 	1.661%	  
	 	12	  	  	 	0.74% 75,166,000	  	  	 	1,559,000	  	  	 	1.687%	  
	 	13	  	  	 	0.75% 73,584,000	  	  	 	1,582,000	  	  	 	1.712%	  
	 	14	  	  	 	0.77% 71,977,000	  	  	 	1,607,000	  	  	 	1.739%	  
	 	15	  	  	 	0.78% 70,346,000	  	  	 	1,631,000	  	  	 	1.765%	  
	 	16	  	  	 	0.79% 68,690,000	  	  	 	1,656,000	  	  	 	1.792%	  
	 	17	  	  	 	0.80% 67,009,000	  	  	 	1,681,000	  	  	 	1.819%	  
	 	18	  	  	 	0.81% 65,302,000	  	  	 	1,707,000	  	  	 	1.847%	  
	 	19	  	  	 	0.83% 63,569,000	  	  	 	1,733,000	  	  	 	1.876%	  
	 	20	  	  	 	0.84% 61,809,000	  	  	 	1,760,000	  	  	 	1.905%	  
	 	21	  	  	 	0.85% 60,023,000	  	  	 	1,786,000	  	  	 	1.933%	  
	 	22	  	  	 	0.86% 58,210,000	  	  	 	1,813,000	  	  	 	1.962%	  
	 	23	  	  	 	0.88% 56,369,000	  	  	 	1,841,000	  	  	 	1.992%	  
	 	24	  	  	 	0.89% 54,500,000	  	  	 	1,869,000	  	  	 	2.023%	  
	 	25	  	  	 	0.90% 52,602,000	  	  	 	1,898,000	  	  	 	2.054%	  
	 	26	  	  	 	0.92% 50,676,000	  	  	 	1,926,000	  	  	 	2.084%	  
	 	27	  	  	 	0.93% 48,720,000	  	  	 	1,956,000	  	  	 	2.117%	  
	 	28	  	  	 	0.95% 46,734,000	  	  	 	1,986,000	  	  	 	2.149%	  
	 	29	  	  	 	0.96% 44,718,000	  	  	 	2,016,000	  	  	 	2.182%	  
	 	30	  	  	 	0.97% 42,671,000	  	  	 	2,047,000	  	  	 	2.215%	  
	 	31	  	  	 	0.99% 40,593,000	  	  	 	2,078,000	  	  	 	2.249%	  
	 	32	  	  	 	1.00% 38,483,000	  	  	 	2,110,000	  	  	 	2.284%	  
	 	33	  	  	 	1.02% 36,341,000	  	  	 	2,142,000	  	  	 	2.318%	  
	 	34	  	  	 	1.04% 34,167,000	  	  	 	2,174,000	  	  	 	2.353%	  
	 	35	  	  	 	1.05% 31,959,000	  	  	 	2,208,000	  	  	 	2.390%	  
	 	36	  	  	 	1.07% 29,718,000	  	  	 	2,241,000	  	  	 	2.425%	  
	 	37	  	  	 	1.08% 27,442,000	  	  	 	2,276,000	  	  	 	2.463%	  
	 	38	  	  	 	1.10% 25,132,000	  	  	 	2,310,000	  	  	 	2.500%	  
	 	39	  	  	 	1.12% 22,786,000	  	  	 	2,346,000	  	  	 	2.539%	  
	 	40	  	  	 	1.13% 20,405,000	  	  	 	2,381,000	  	  	 	2.577%	  
	 	41	  	  	 	1.15% 17,987,000	  	  	 	2,418,000	  	  	 	2.617%	  
	 	42	  	  	 	1.17% 15,533,000	  	  	 	2,454,000	  	  	 	2.656%	  
	 	43	  	  	 	1.19% 13,041,000	  	  	 	2,492,000	  	  	 	2.697%	  
	 	44	  	  	 	1.20% 10,511,000	  	  	 	2,530,000	  	  	 	2.738%	  
	 	45	  	  	 	1.22% 7,943,000	  	  	 	2,568,000	  	  	 	2.779%	  
	 	46	  	  	 	1.24% 5,335,000	  	  	 	2,608,000	  	  	 	2.823%	  
	 	47	  	  	 	1.26% 2,688,000	  	  	 	2,647,000	  	  	 	2.865%	  
	 	48	  	  	 	1.28%0	  	  	 	2,688,000	  	  	 	2.909%	  
				  	  
	  
	 	  	  
	  
	 	  	  
	  
	 
				  	 	44.00%	  	  				  			
				  				  				  	 	100.000%	  

  
 110

 Schedule 8 
 Form of Compliance Certificate 
  

	To:	BNP Paribas S.A. (the “Agent”) 

From: [—] (the “[—]”) 

Date: [Ÿ] 

Dear Sirs, 
 We refer to an agreement (the
“Agreement”) dated                         and made between (1) the banks and financial institutions listed
in Schedule 1 of the Agreement as lenders and swap providers, (2) yourselves as Agent (3) yourselves as Security Trustee and (4) yourselves as KEIC Agent (as from time to time amended, varied, novated or supplemented). 

Terms defined or construed in the Agreement have the same meanings and constructions in this Certificate. 

We attach the relevant calculation details applicable to the last four (4) financial quarters ending [•] (the “Relevant
Period”) which confirm that:- 
  

	1	The average DSCR in respect of the immediately preceding four (4) financial quarters [was/was not] equal to or greater than1:10x. Therefore the condition contained
in clause 9.1.219.1.19 of the Agreement [has/has not] been complied with in respect of the Relevant Period. 

  

	2	The average DSCR in respect of the immediately preceding two (2) financial quarters [was at all times equal to or greater than/fell below] 1.06x. Therefore the
condition contained in clause 9.1.219.1.19 of the Agreement [has/has not] been complied with. 

  

	3	The Leverage Ratio for the immediately preceding four (4) financial quarters did not exceed 4:1. Therefore, the contained in clause 9.1.219.
1.19 of the Agreement [has/has not] been complied with 

Signed:                        
                         
 Duly authorised representative of 
 MiNT LNG IV, LTD 

  
 111

 Exhibit A 
 MiNT LNG I Long Form Confirmation Letters between the Borrower and BNP Paribas S.A. dated 20 August 2008 and 28 August 2008 

MiNT LNG II Long Form Confirmation Letters between the Borrower and BNP Paribas S.A. dated 20 August 2008 and 28 August 2008

 MiNT LNG III Long Form Confirmation Letters between the Borrower and BNP Paribas S.A. dated 22 August 2008 and 29 August
2008 
 MiNT LNG IV Long-Form Confirmation Letters Letter between the Borrower and BNP Paribas
S.A. dated 22 August 2 October 2008 and 29 Augustas amended on 9 October 2008 

  
 112

 IN WITNESS of which the parties to this Agreement have executed this Agreement the day and year first
before written. 
  

					
	 SIGNED by
	  	)	  	
	 duly authorised for and on behalf
	  	)	  	
	 of MiNT LNG IV, LTD.
	  	)	  	
			
	 SIGNED by
	  	)	  	
	 duly authorised for and on behalf
	  	)	  	
	 of BNP PARIBAS S.A. (as a Lender and a Swap Provider)
	  	)	  	
			
	 SIGNED by
	  	)	  	
	 duly authorised for and on behalf
	  	)	  	
	 of CALYON (as a Lender and a Swap Provider)
	  	)	  	
			
	 SIGNED by
	  	)	  	
	 duly authorised for and on behalf
	  	)	  	
	 of DNB NOR BANK ASA (as a Lender and a Swap Provider)
	  	)	  	
			
	 SIGNED by
	  	)	  	
	 duly authorised for and on behalf
	  	)	  	
	 of SOCIETE GENERALE
	  	)	  	
	 (as a Lender and a Swap Provider)
	  	)	  	
			
	 SIGNED by
	  	)	  	
	 duly authorised for and on behalf
	  	)	  	
	 of THE BANK OF TOKYO-MITSUBISHI UFJ, LTD.
	  	)	  	
	 (as a Lender and a Swap Provider)
	  	)	  	
			
	 SIGNED by
	  	)	  	
	 duly authorised for and on behalf
	  	)	  	
	 of SUMITOMO MITSUI BANKING CORPORATION
	  	)	  	
	 BRUSSELS BRANCH
	  	)	  	
	 (as a Lender)
	  	)	  	
			
	 SIGNED by
	  	)	  	
	 duly authorised for and on behalf
	  	)	  	
	 of SMBC CAPITAL MARKETS, INC.
	  	)	  	
	 (as a Swap Provider)
	  	)	  	
			
	 SIGNED by
	  	)	  	
	 duly authorised for and on behalf
	  	)	  	
	 of BNP PARIBAS S.A.
	  	)	  	
	 (as Agent)
	  	)	  	

  
 113

							
	 SIGNED by
	  	 	)	  	  	
	 duly authorised for and on behalf
	  	 	)	  	  	
	 of BNP PARIBAS S.A.
	  	 	)	  	  	
	 (as the Security Trustee)
	  	 	)	  	  	
			
	 SIGNED by
	  	 	)	  	  	
	 duly authorised for and on behalf
	  	 	)	  	  	
	 of BNP PARIBAS S.A.
	  	 	)	  	  	
	 (as the KEIC Agent)
	  	 	)	  	  	

  
 114

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00202-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00202-of-00352.parquet"}]]