Document:

<PAGE>   1

NAUTA DUTILH

                                         ADVOCATEN NOTARISSEN BELASTINGADVISEURS

                                  ------------
                                 [            ]
                                 [            ]
                                 [    LOGO    ]
                                 [            ]
                                 [            ]
                                  ------------

                            UNAUTHORIZED TRANSLATION

                                  of a deed of

                              Economic transfer of:

        the business complex and laboratory, situated on a parcel of land, which
        parcel is situated in the zoningplan Leeuwenhoek, on the corner of the
        Archimedesweg and the Zernikedreef at Leiden, recorded in the
        landregister as municipality Leiden, section X number 4050

                            Deed dated 6 January 1999

<PAGE>   2

                                        Economic transfer of registered property
                                                                 OS/LA 8002.4273
                                                                    Document 001

This day, sixth day of January nineteen hundred and ninety-nine, there appeared
before me, Luutzen Frederik Tamminga, LL.M., civil law notary officiating in
Rotterdam:

1. a.   Mr Jari Ilmari Karlson, controller, residing at 2281 SV Rijswijk,
        Bilderdijklaan 40, born at Turku, Finland, on the twenty-eighth day of
        May one thousand nine hundred sixty-one, married, holder of a Finnish
        passport with number 2371571,

        for the purposes of this matter acting as mandatary authorized in
        writing by :

        Mr Stuart Lewis Melton, directeur, residing at Caversham Woods 77,
        Pittsford, NY 14534,

        United States of America, born at Peoria, Illinois, United States of
        America on the twenty-ninth day of December one thousand nine hundred
        forty-six, married, for the purposes of this matter acting as managing
        director A of the private company with limited liability: GENENCOR
        INTERNATIONAL B.V., having its registered office at Delft, address: 2288
        EK Rijswijk, Verryn Stuartlaan 1; and

   b.   Mr Johannes Cornelis van der Laan, research and development director,
        residing at 3124 BA Schiedam, Atalantahof 19, born at Amsterdam on the
        twentieth day of December one thousand nine hundred fifty-five, married,
        holder of passport with number N39086638, acting in his capacity of
        managing director B of the aforementioned compay: Genencor International
        B.V.,

    the appearers sub 1 a. en b., acting in said capacities, as such legally
    representing Genencor International B.V.,

    -   Genencor International B.V. hereinafter referred hereinafter called
        "Vendor"; and

2.  Mr Olaf Ansgar Joseph Hermanus Smit, candidate civil-law notary, residing at
    3011 TT Rotterdam, Admiraliteitskade 220, born at Breda on the fifteenth day
    of February one thousand nine hundred seventy-four, unmarried, holder of
    passport number L080762, for the purposes of this matter acting as mandatary
    authorized in writing by:

    a private company with limited liability:  ABN AMRO ONROEREND GOED LEASE EN
    FINANCIERINGEN B.V., having its registered office at Amsterdam, address:
    1112 XP Diemen,

<PAGE>   3

    Wisselwerking 22 (correspondence-address: p.o. box 1020, 1000 BA Amsterdam),
    registered in the Trade-register of the Chamber of Commerce and Industries
    at Amsterdam with number 184.851,

    hereinafter called "Buyer".

    The appearers, acting as stated, considering:

-   that Vendor has and has been since the start of the construction economical
    owner of: the business complex and laboratory, erected at the expense of
    Vendor, situated on a parcel of land, owned by the municipality of Leiden,
    which parcel has been granted to Buyer under a ground lease by the
    municipality of Leiden, and which parcel is situated in the zoningplan
    Leeuwenhoek, on the corner of the Archimedesweg and the Zernikedreef at
    Leiden, forming a part measuring approximately thirty-one are and seventy
    centiare marked at the spot, of the parcel, recorded in the landregister as
    municipality Leiden, section X number 4050 (formerly 4031), as indicated in
    outline on the map, marked LV 2265, dated the thirteenth day of July one
    thousand nine hundred ninety-six, altered the ninth day of December one
    thousand nine hundred ninety-eight, which map shall be attached to this
    deed, the buildings hereinafter referred to as "the Property Sold";

-   that Vendor is erecting a business complex and a laboratory, to be realized
    in confirmity with a building contract concluded with a building contractor,
    known to parties, hereinafter referred to as the "Building Contractor", the
    building contract hereinafter referred to as the "Building Contract" and in
    conformity with the construction specifications and the construction
    specification drawings associated with it, which documents are known to the
    parties;

-   that the Property Sold will be transferred in economic sense by Vendor to
    Buyer and Buyer will accept in economic sense on the date, on which the
    business complex and the laboratory will be handed over by the Building
    Contractor to the Vendor (this date hereinafter referred to as the
    "Completion Date"), provided that the business complex with the laboratory
    is erected in conformity with the Building Contract and in conformity with
    the construction specifications and the construction specification drawings
    associated with it;

-   that occupation of the Property Sold shall take place only after the
    Completion Date;

<PAGE>   4

-   that Buyer has the intention to make the Property Sold available to Vendor
    as of the Date of Completion on the basis of an agreement of lease;

declared the following:

PURCHASE AGREEMENT

The Vendor hereby sells to the Buyer and Buyer hereby buys from the Vendor the
Property Sold.

ECONOMIC TRANSFER

With effect from the Completion Date the Vendor delivers in economic sense the
Property Sold to the Buyer who accepts this in economic sense with effect from
the Completion Date.

The Vendor guarantees that he is empowered to sell and deliver in economic sense
the Property Sold.

ANCILLARY PROPERTY

Also the Vendor delivers with effect from the Completion Date to the Buyer who
accepts with effect from the Completion Date the movables that are intended to
serve the Property Sold permanently as referred to in section 254 of Book 3 of
the Civil Code, these movables hereinafter also called "the Ancillary Property".

PAYMENT OF PURCHASE PRICE

The purchase price of the Property Sold and the Ancillary Property amounts to
the total of the costs that Vendor has made on the matter of the building of the
buildings erected on the land, up to a maximum of eight million (NLG
8.000.000,--) excluding VAT.

The purchase price will be paid by the Vendor to the Buyer on the Completion
Date.

APPLICABLE PROVISIONS

The purchase and transfer in economic sense shall be subject to the following

PROVISIONS

EXPENSES AND TAXES

Article 1.

All the expenses, taxes and other burdens falling on this agreement of purchase
and sale and on the economic and the actual deliveries of the Property Sold
shall be for account of the Vendor.

USE OF THE PROPERTY SOLD

<PAGE>   5

Article 2.

The Buyer has stated that he wishes to use the Property Sold as business complex
and laboratory.

The Vendor has stated that he is not aware that the Property Sold should lack
one or more properties that would be necessary for a normal use as stated above
and that the Buyer could consequently expect in reason, or that the intended use
would not be permitted on the strength of any rules of private or public law.

LEGAL STATE OF THE PROPERTY SOLD

Article 3.

The Vendor guarantees that no retention rights are/shall be exercised with
regard to the Property Sold.

Article 4.

The Vendor guarantees the correctness of the following:

a.  the Property Sold is at the Completion Date free of hire and other user
    rights, empty, vacated with the exception of any movables sold along with it
    and unclaimed; it is not being used by third parties without right or title;

b.  For the Vendor there are at the Completion Date no obligations to third
    parties on the strength of any pre-emption right, option, right of
    repurchase or hire purchase;

c.  the Vendor does not know whether the Property Sold is the subject of any
    (pending application for advice on) designation or a designation order or
    register entry:

    1.  as a protected monument in the sense of section 3, 4 or 6 of the
        Historic Buildings and Ancient Monuments Act;

    2.  as a protected town or village view or proposal for the purpose as
        referred to in section 35 of the Historic Buildings and Ancient
        Monuments Act;

    3.  by the municipality or province as a protected town or village view;

d.  the Vendor does not know whether the Property Sold is included in a town or
    village renewal plan or has been designated for town or village renewal or
    has been included in a designation as referred to in section 2 or section 8
    or in a proposal as referred to in section 6 or section 8a of the Municipal
    Priority Rights Act;

e.  in connection with the Property Sold no legal action or arbitration is
    pending.

ACTUAL CONDITION OF THE PROPERTY SOLD

<PAGE>   6

Article 5.

1.  On the Completion Date the Property Sold shall be delivered and accepted in
    the actual condition in which it is then, entirely vacated with the
    exception of any movables possibly sold along with it.

2.  If the size stated above for the Property Sold is not correct or not
    complete neither the Vendor nor the Buyer shall derive any right from that.

ACTUAL TRANSFER/PROFITS AND LOSSES

Article 6.

The actual transfer of the Property Sold will be effected on the Completion
Date.

From the time of transfer the profits of the Property Sold shall be for the
benefit of the Buyer and the expenses shall be for account of the Buyer.

TRANSFER OF THE RISK

Article 7.

1.  The risk of the Property Sold shall pass to the Buyer at the time of the
    actual transfer agreed in article 6.

2.  In deviation from the provisions of section 7:10 of the Civil Code, in the
    event of rescission of the purchase agreement, even if it is brought about
    by the Buyer, the risk of the Property Sold shall be for the Buyer until the
    retransfer to the Vendor.

RESCISSION

Article 8.

1.  All resolutory conditions that might have been agreed will cease to operate
    on the Completion Date and will be annulled entirely on the Completion Date.
    So with effect from the Completion Date neither the Vendor nor the Buyer can
    still invoke a resolutory condition in respect of this purchase and transfer
    in economic sense.

2.  The parties explicitly intimate that they wish to exclude every possibility
    of rescission or annulment of this purchase and transfer in economic sense
    and are hereby doing this in so far as the law allows them to do so.

    For those cases in which exclusion of rescission or annulment is not legally
    possible, they intimate as their explicit desire that the consequences of a
    possible rescission or annulment shall remain as limited as possible.

TRANSFER IN AN ECONOMIC SENSE

<PAGE>   7

Article 9.

    The possession and enjoyment of the Property Sold shall be delivered to the
    Buyer on the completion Date and with effect from the Completion Date the
    Property Sold shall belong in an economic sense to the Buyer.

DEFAULT AND FINES

Article 10.

1.  If the Vendor, after notice of default has been given to him by writ, during
    a period of fourteen days neglects to fulfil one or more of its obligations
    by virtue of this agreement the Vendor shall forfeit for the benefit of the
    Buyer an immediately payable

    penalty of one million Dutch guilders

    (NLG 1.000.000,--), such without prejudice to the obligation to fulfil
    towards the Buyer the agreement and without prejudice to the right of the
    Buyer to claim compensation of damages and to the other rights of the Buyer.

2.  If the Buyer, after notice of default has been given to him by writ, during
    a period of fourteen days neglects to fulfil any obligation by virtue of
    this agreement the Buyer shall forfeit for the benefit of the Vendor an
    immediately payable penalty of one million Dutch guilders (NLG
    1.000.000,--), such without prejudice to the obligation to fulfil towards
    the Vendor the agreement and without prejudice to the right of the Vendor to
    claim compensation of damages and to the other rights of the Vendor.

3.  A fine shall be forfeited no matter whether the shortcoming is culpable or
    not.

INDIVISIBILITY

Article 11.

1.  The obligations flowing from this Deed on the part of the Vendor or
    connected therewith shall be indivisible where the Vendor is concerned.

2.  The obligations flowing from this Deed on the part of the Buyer or connected
    therewith shall be indivisible where the Buyer is concerned.

TRANSFER OF ANCILLARY PROPERTY

Immediately after the execution of this deed the ownership of the Ancillary
Property shall be transferred in a legal sense to the Buyer in the condition in
which the Ancillary Property now is and free from pledges. Also immediately
after the execution of this deed the Ancillary Property shall be accepted by the
Buyer in the above-mentioned condition.

<PAGE>   8

TRANSFER TAX/TURNOVER TAX

The appearers declared that this transfer is encumbered with turnover tax by
virtue of the provisions of article 11(1) beginning and (a)(1) of the Turnover
Tax Act 1968. This turnover tax shall be for account of the Buyer and has not
been included in the said purchase price.

In respect of the transfer tax the exemption referred to in section 15 (1)
beginning and (a) of the Act on Taxes on Legal Transactions is invoked because
the Property Sold has not been used as a business assets.

REGISTRATION

Neither this deed nor any copy of or extract from it shall be intended to be
registered for the transfer of the Property Sold in the public registers
intended for the purpose because this deed does not contain a transfer of
registered property.

CHOICE OF DOMICILE

In respect of the performance of this agreement, also for fiscal consequences,
domicile is chosen at my, notary's office.

MANDATES AND POWERS OF ATTORNEY

The mandates for the appearers are evidenced by two private powers of attorney,
which will be attached to this instrument. Sufficient evidence of the powers of
attorney included in the mandates has been given to me, notary.

The appearers declared that they accepted the relevant mandates.

FINAL PROVISIONS

1.  The capitalized headings are intended to increase the readability of this
    instrument and neither Vendor nor Buyer can derive any right from
    them.

2.  Unless something else has been stated or agreed in more detail all
    communications, notifications and requests or demands that are made or
    brought by virtue of this agreement must be effected by telefax, by
    registered letter or by writ.

    If communications, notifications and requests or demands have been effected
    by telefax they must be confirmed immediately by registered letter or writ
    on pain of nullity, in which connection the date of despatch of the telefax
    message shall be the date of receipt.

3. This agreement shall be subject to the General Extension of Time-limits Act.

4.  This agreement and its performance shall be governed exclusively by Dutch
    law.

CONCLUSION

<PAGE>   9

The appearers are known to me, notary.

WHEREOF AN ORIGINAL INSTRUMENT

was executed in Rotterdam on the date stated at the head of this instrument.

After the gist of this instrument had first been stated to the appearers by me,
notary, they declared unanimously that they had taken note of the content of
this instrument and did not desire it to be read out in full.

Subsequently, upon being read out in part, this instrument was signed by the
appearers and me, notary.<PAGE>   1
                                                                    EXHIBIT 10.9

                                      LEASE

This Lease made and executed as of the 28th day of August, 1991 by and between
EASTMAN KODAK COMPANY, a New Jersey Corporation, having an office at 343 State
Street, Rochester, New York, (hereinafter referred to as "Landlord") and
GENENCOR INTERNATIONAL, INC., a Delaware corporation, having an office at 4
Cambridge Place, 1870 Winton Road South, Rochester, New York (hereinafter
referred to as "Tenant").

        1.     DEMISED PREMISES AND IMPROVEMENTS THEREON

               Landlord, in consideration of the terms herein, grants and leases
to Tenant, and Tenant hereby leases from Landlord, on the terms, herein:

               All that certain parcel of land and improvements, buildings (but
not equipment or other personalty acquired by separate bill of sale from
Landlord) in the Town of Greece and City of Rochester, County of Monroe, State
of New York shown in Exhibit "A" hereto, including existing shared access to the
premises and loading dock area (except as the context may otherwise require, the
above mentioned premises are hereinafter referred to as "the Premises,"); a
legal description of the leasehold property conveyed under this agreement, is
more particularly set forth in Exhibit "A-1" hereto;

               To have and to hold the Demised Premises for and during the term
hereinafter described; together with any and all appurtenances, rights,
interests, and easements, if any;

        2.     TERM AND DURATION

               The Term of this Lease ("lease term") shall extend for a period
of fifty (50) years, beginning on the 1st day of January, 1990.

        3.     SHORT FORM OR MEMORANDUM OF LEASE SUITABLE FOR RECORDING

               Each party agrees, at the request of the other party, to promptly
execute and deliver to the requesting party a short form or Memorandum of Lease
duly acknowledged and in recordable form.

        4.     RENT

               Tenant covenants and agrees to pay to Landlord at such place as
Landlord shall designate in writing, for the lease term, a rental of One Dollar
($1.00) per year payable annually at the commencement of the lease year.

        5.     USE AND OCCUPANCY

               The Tenant shall maintain and operate the Demised Premises for
manufacturing, laboratory, and office purposes, or for other lawful purposes not
inconsistent with the zoning ordinances and other applicable rules and
regulations of the City of Rochester and Town of Greece.

<PAGE>   2

        6.     ASSIGNMENT AND SUBLETTING

               This Lease shall not be assignable nor the Premises sublettable
by either party without written approval of the other party which approval shall
not be unreasonably withheld.

        7.     TAXES, ASSESSMENTS AND UTILITIES

               a.     Tenant shall reimburse Landlord for all real estate taxes
attributable to the Premises throughout the lease term.

               b.     On the commencement date of this Lease, Landlord shall
provide the following utilities and services and Tenant shall pay for such
utilities and services at the same rates Kodak charges back to its production
and manufacturing units situated at Kodak Park including a capital financing
charge in lieu of the capital asset distribution normally allocated to such
unit:

               1.     Steam/condensate

               2.     Electric

               3.     Storm/Sewer

               4.     Fire protection water and processed water

               5.     Drinking water

               6.     Electrical Switchgear facility

               7.     Computer links

               8.     Hazardous Waste Removal/incineration

               9.     General Expenses including but not limited to security,
                      fire protection, bus access, cafeteria access and the like

               Landlord warrants and represents that rates for future years will
be similar to, and not in excess of, the charges for the above utilities and
services which Kodak charges back to its production and manufacturing units
throughout Kodak Park. Tenant will comply with any Landlord standards and
procedures normally applicable to such utilities and services.

               If Tenant finds alternative services to replace any of the above
utilities or services, the applicable charges referred to above shall be
terminated upon 30 days' written notice to Landlord.

               Tenant has or will construct and maintain at its expense sanitary
sewer line(s) to be connected directly from the Premises to a municipal sewer.
Tenant shall cease to use the sanitary sewer of Landlord now connected to the
Demised Premises.

<PAGE>   3

        8.     LIABILITY INSURANCE

               Upon Landlord's request, a certificate of insurance, or binder,
of such insurance insuring the interests of Tenant shall be furnished to
Landlord at the commencement of the lease term and upon each renewal thereof.

               Tenant agrees to maintain, throughout the lease term,
comprehensive liability insurance against claims for injury to persons or damage
to property arising out of its use and occupancy of the Demised Premises, any
such policies of insurance to be written with a company of recognized
responsibility and reasonably acceptable to Landlord.

        9.     CASUALTY INSURANCE

               a.     Tenant will, during the lease term cause the buildings and
improvements on the Premises to be insured against all risk of loss or damage to
full replacement value. The insurance policies shall be with a responsible and
reputable insurance company, reasonably acceptable to Landlord and shall contain
the standard mortgagee endorsement.

               b.     All insurance policies carried by Tenant pursuant to this
Section 9 shall be issued in the name of Tenant, any subtenant of the Premises,
the Landlord, and any leasehold mortgagee, as their respective interests may
appear. Tenant shall have the right to make all adjustments of loss and execute
all proofs of loss in its name and/or in Landlord's name. Subject to any loss
payable endorsements in favor of the leasehold mortgagee, the proceeds of such
insurance in case of loss shall be payable to Tenant as trust funds and used by
Tenant for the purpose of restoring and rebuilding the improvements located on
the Premises.

               c.     Tenant may maintain for his own account any insurance not
required by this Lease or insurance required by this Lease with greater coverage
in scope and amounts, and the proceeds thereof belong to Tenant.

        10.    MUTUAL RELEASE AND WAIVER OF SUBROGATION

               Landlord and Tenant hereby waive on behalf of themselves and
their respective insurers, any claims that either may have against the other for
loss or damage resulting from perils covered by the standard form of all risk
insurance. It is understood that this waiver is intended to extend to all such
loss or damage whether or not the same is caused by the fault or neglect of
either Landlord or Tenant and whether or not insurance is in force. If required
by policy conditions, each party shall secure from its property insurer a waiver
of subrogation endorsement to its policy, and deliver a copy of such endorsement
to the other party to this Lease if requested.

        11.    INDEMNITY

               Landlord and Tenant each agree to indemnify and hold each other
harmless from and against any and all claims, actions, damages, liability, loss
of life, personal injury and damages to property arising from or out of the
indemnitor's conduct and actions in regard to the Premises and areas adjoining
the Premises. Landlord and Tenant mutually agree to comply with all
environmental, health, safety and recordkeeping and other applicable
requirements of any

<PAGE>   4

governmental agency relating to the Premises or operations at the Premises
including but not limited to the use and discharge of hazardous chemical and
biological material upon and adjoining the Premises.

        12.    BUILDINGS, IMPROVEMENTS AND ALTERATIONS

               a.     Landlord is the owner of the existing building on the
Premises at the commencement of this Lease.

               b.     Tenant shall have the right, at all times during the Lease
term and at its own cost and expense, to make such changes, improvements,
alterations and additions to the Premises as it may desire subject to Landlord
approval which will not unreasonably be withheld.

               c.     Any future capital improvements to the existing building,
any additional building, or other additions of fixtures and improvements, shall
remain and be the property of the Tenant during the term of this Lease, and
Tenant shall be permitted to depreciate said property in accordance with
applicable state and federal tax laws; Landlord shall have no right or interest
in such depreciation of Tenant's buildings, improvements and fixtures.

        13.    COMPLIANCE WITH LAWS

               a.     Except as may otherwise be the responsibility of Landlord
under the terms of this Lease, Tenant shall comply with all present and future
laws, ordinances, orders, rules, regulations, and requirements with respect to
the Premises, the buildings and improvements thereon or hereafter erected
thereon by Tenant, or the use or occupancy thereof. With respect to the
above-ground chemical storage tanks present at the premises, it shall be
Landlord's responsibility to conduct all required integrity assessments and
upgrades in accordance with all applicable Federal or New York State laws and
regulations as of January 1, 1990, and the Kodak Park Storage Tank Improvement
Program referenced in New York State Order on Consent Index No. D8-6001-89-1
dated June 7, 1989. It shall be Tenant's responsibility to comply with all
applicable Federal or New York State laws or regulations respecting the
operation and management of such tanks after January 1, 1990 except for the
upgrading of the tanks by Landlord, as more particularly set forth above.

               b.     Tenant shall have the right, at its sole cost, to contest
the validity or applicability of any real estate tax law, ordinance, order,
rule, or regulation, and Tenant shall have the right to delay observance thereof
and compliance therewith until such contest is finally determined and is no
longer subject to appeal. Tenant may delay observance and compliance with any
such law pending the prosecution of such proceeding provided that such
compliance may be legally delayed without subjecting Landlord to any criminal
liability or fine or without in any way jeopardizing the ownership of the
property. Tenant will hold Landlord harmless from any cost related to such
contest or proceeding.

        14.    HAZARDOUS SUBSTANCES; INDEMNITY

               a.     Landlord represents and warrants that any handling,
transportation, storage, treatment or usage of toxic or hazardous substances
that has occurred on the Premises to January 1, 1990, has been in substantial
compliance with all applicable federal, state and local

<PAGE>   5

laws, regulations, and ordinances. Landlord further represents and warrants that
no consent order by any state or Federal Agency has been issued in regard to
said premises, and that Landlord will disclose to Tenant any substantial leak,
spill, release, discharge, emission, or disposal of toxic or hazardous
substances which has occurred on the Premises prior to January 1, 1990.

               b.     Landlord shall indemnify, defend (with counsel acceptable
to Tenant) and hold Tenant and its officers, employees and agents harmless from
any claims, judgments, damages, penalties, fines, costs, liabilities (including
sums paid in settlement of claims) or loss including attorneys' fees, consultant
fees, and expert fees (consultants and experts to be selected by Tenant) that
arise during or after the lease term from or in connection with the presence or
suspected presence of toxic or hazardous substances in the soil, or groundwater
at the Premises, or the investigation or remediation cleanup or removal thereof,
unless the toxic or hazardous substances are present (a) solely as a result of
the conduct of Tenant, its officers, employees or agents after January 1, 1990
or (b) solely as a result of the conduct of third parties.

               c.     Tenant shall indemnify, defend (with counsel acceptable to
Landlord) and hold Landlord and its officers, employees and agents harmless from
any claims, judgments, damages, penalties, fines, costs, liabilities (including
sums paid in settlement of claims) or loss including attorneys' fees, consultant
fees, and expert fees (consultants and experts to be selected by Landlord) that
arise during or after the lease term from or in connection with the presence or
suspected presence of toxic or hazardous substances in the soil, or groundwater
at the Premises, or the investigation or remediation cleanup or removal thereof,
unless the toxic or hazardous substances are present (a) solely as a result of
the conduct of Landlord, its officers, employees or agents, or (b) solely as a
result of the conduct of third parties.

               d.     As used herein, the term "toxic or hazardous substances"
means any toxic or hazardous substance, material or waste which is or becomes
regulated by any appropriate governmental authority. The term "toxic or
hazardous substances" includes, without limitation, any material or substance
which is (i) defined as a "hazardous substance" or "hazardous waste" under
applicable state or federal law, (ii) petroleum, (iii) asbestos, (vii) defined
as a "regulated substance" pursuant to Subchapter IX, Solid Water Disposal Act
(Regulation of Underground Storage Tanks), U.S.C. ss.6991 et seq., or (v)
defined as a "pesticide" pursuant to the Federal Insecticide, Fungicide and
Rodenticide Act, as amended.

        15.    ENVIRONMENTAL REPORTS; FURTHER INVESTIGATION AND FOLLOW-UP

               [Intentionally Deleted]

        16.    REAL ESTATE TITLE REPRESENTATION

               The Landlord warrants and represents to the Tenant that Landlord
owns the Premises in fee simple and that there exists no mortgage, judgment or
other lien affecting the Premises.

        17.    DAMAGE CLAUSE

               Should the whole or any part of the buildings or improvements on
the Premises be partially or wholly damaged or destroyed by fire or other
insured casualty after the

<PAGE>   6

commencement of the Lease term, such destruction or damage shall not operate to
terminate this Lease, but this Lease shall continue in full force and effect,
except as otherwise provided herein. Tenant, to the extent that insurance
proceeds are available for said loss or damage, agrees to restore, rebuild or
repair the buildings and improvements to a condition as near as possible to that
existing prior to the damage. The insurance proceeds payable as a result of such
damage or destruction of said buildings or improvements shall be paid to Tenant
in trust for restoration and rebuilding, subject to the rights and interests of
any Leasehold Mortgagee.

        18.    DEFAULT CLAUSES

               In the event that Tenant shall default or fail in the performance
of any covenant or agreement on its part in this Lease, and such default is not
cured for a period of ninety (90) days after Tenant receives written notice of
default from Landlord, or if such default cannot, with due diligence, be cured
within ninety (90) days, and Tenant shall not have commenced to remedy the same
within such period and shall not be proceeding with due diligence and in good
faith to remedy it, then, and in such case, Landlord may at Landlord's option,
on 90 days' written notice by Landlord, purchase Tenant's interest in this
Lease, as more particularly set forth in paragraph 22 herein, except that
Landlord shall be given a set-off or credit against the purchase price for the
amount of the default, and the balance of the purchase price, less the amount
needed to cure said default, shall be remitted directly to the Tenant.

        19.    CONDEMNATION

               a.     If the entire Premises shall be taken by the right of
eminent domain for any public use, this Lease shall then expire on the later of
the date when title to the Premises so taken shall vest in the condemning
authority or the date when any possession is required to be surrendered,
whichever is later.

               b.     If such a substantial portion of the premises or buildings
or improvements (including automobile parking) constructed thereon shall be
taken so as to make the remaining portion unusable for the purposes to which the
Premises shall then be devoted, Tenant shall have the right to cancel or
terminate this Lease on forty-five (45) days' written notice. On such taking,
Tenant shall pursue in its respective name its rights, such remedies and make
such claims as it may have against the authority exercising eminent domain or
other lawful taking, Landlord agrees that out of condemnation proceeds available
in regard to said taking, (i) the value of Tenant's Lease prior to such taking,
(ii) Tenant's improvements and (iii) Tenant's moving expenses and other lawful
Tenant claims shall take priority over any of Landlord's claims in said
proceeding.

        20.    ESTOPPEL CERTIFICATES

               Each party shall, at its expense within ten (10) days after
request by the other party or any Leasehold Mortgagee, certify by written
instrument in recordable form:

               a.     That this Lease is unmodified and in full force and effect
(or that the lease is in full force and effect as modified and stating the
modification);

<PAGE>   7

               b.     The dates, if any, to which the rent and impositions, and
other charges hereunder have been paid in advance;

               c.     Whether the other party is in default in the performance
of any covenant, condition or agreement to be performed by that party and the
nature of the default, if any; and

               d.     Such other reasonable information as is requested.

        21.    PURCHASE OPTION

               At any time during the Lease term, upon ninety (90) days' written
notice to Landlord, Tenant shall have the right to purchase the Premises from
the Landlord for the sum of One Dollar ($1.00). All expenses of said purchase
including, New York State Gains tax, any sales tax, transfer tax, title
insurance, search, survey and recording charges, as well as any redated and
revised environmental Phase I and Phase II studies, shall be the sole expense of
the Tenant.

        22.    PURCHASE OF PREMISES BY LANDLORD FROM TENANT

               Upon ninety (90) days' written notice to Landlord from Tenant,
Landlord hereby agrees to purchase or take by assignment, and Tenant hereby
agrees to sell, or assign to Landlord, all of Tenant's right, title and interest
in this lease, at a value which shall be the greater of

               a.     the contributory "book" value of the Premises in the
amount of $7,159,779, less depreciation, recorded by Tenant in accordance with
generally accepted accounting principles; or

               b.     the fair market value of the Premises without deduction
from said value of the Premises the value of the utilities and services
furnished by the Landlord, including any improvements or costs made by Tenant to
the Premises after January 1, 1990. If Landlord and Tenant cannot agree on the
valuation of the property as set forth above they shall each select an MAI
appraiser to determine said fair market value. If both appraisers are unable to
agree, both appraisers shall select a third MAI Appraiser, whose decision in
this matter shall be final, and not subject to appeal or further judicial
determination by either Party.

               All expenses in regard to the above assignment of lease and/or
transfer of Premises from Tenant to Landlord, including New York State Transfer
Taxes, New York State Gains Tax, expenses etc., shall be the responsibility of
the Landlord.

        23.    RIGHT TO PERFORM FOR OTHER PARTY

               If either Landlord or Tenant shall, after notice and demand, fail
to perform any covenant, condition, or other obligation on its part to be
performed under this Lease, the other party may do so on behalf of the party so
failing to perform.

<PAGE>   8

        24.    WRITTEN NOTICE

               Whenever under the terms of this Lease a written notice or
communication is required or sent, it shall be by Certified Mail, addressed to
Landlord and/or Tenant at its address first above-written or to such other
address as either Landlord or Tenant may designate by written notice to the
other made as herein provided, or by personal service, or express mail. Notice
shall be considered given on the date the Return Receipt Request is signed by
the party receiving notice.

        25.    BINDING ON SUCCESSORS AND ASSIGNS

               Except as otherwise provided in this, Lease, all terms,
covenants, agreements, provisions, and conditions of this Lease shall be binding
on and inure to the benefit of the parties hereto, and their respective
representatives, successors, and assigns. No modification or termination of this
Lease shall be binding unless evidenced by an agreement in writing signed by
Landlord and Tenant.

        26.    NO MERGER

               Notwithstanding any provision of this Lease to the contrary, if
at any time or times during the term of this Lease or any renewal or extension
thereof, Landlord and Tenant shall be the same person, party, or entity, or
Landlord and the Leasehold Mortgagee shall be the same person, party or entity,
Landlord's and tenant's interests and Landlord's and the Leasehold Mortgagee's
interests shall remain separate and distinct and shall not be merged into one
estate so as to cancel, terminate, or extinguish this Lease or the Leasehold
Mortgage by law or otherwise.

        27.    CAPTIONS

               The captions of the Paragraphs of this instrument are solely for
convenience and are not a part of this instrument for the purpose of construing
its meaning or for any other purpose.

        28.    SURRENDER

               Subject to the rights of holders of the mortgages described in
Paragraph 16, upon the expiration or the termination of the Lease term Tenant
shall quit and surrender the Demised Premises and all buildings and improvements
thereon in good condition and repair, except for reasonable wear and tear, and
retention by Tenant of all trade fixtures, equipment, and personal property of
Tenant.

        29.    QUIET ENJOYMENT

               Landlord agrees, covenants, and warrants that so long as Tenant
faithfully performs the terms, agreements, provisions, covenants, and conditions
of this Lease in a timely fashion within the grace periods and extended periods
for unavoidable delays provided for herein, Tenant shall peaceably and quietly
have, hold, and enjoy the Premises for the lease term

<PAGE>   9

without molestation or disturbance by or from Landlord and free of any and all
encumbrances created or suffered by Landlord.

        30.    NO WAIVER

               No waiver of any covenant or condition contained in this Lease or
of any breach of any such covenant or condition shall constitute a waiver of any
subsequent breach of such covenant or condition by either party or justify or
authorize the nonobservance on any other occasion of the same or any other
covenant or condition hereof by either party.

        31.    INTERPRETATION

               This Lease shall be construed in accordance with the laws of the
State of New York. Whenever the contents of any provision shall require it, the
singular number shall be held to include the plural number, the neuter gender
shall include the masculine and feminine, and vice versa.

        32.    ENTIRE AGREEMENT

               This Lease contains the entire agreement of the parties hereto
with respect to the lease of the Premises and this lease may not be amended,
modified, released, or discharged in whole or in part except by an instrument in
writing signed by the parties hereto, their respective successors or assigns.

        IN WITNESS WHEREOF, Landlord and the Tenant have caused these presents
to be executed on the day and year first above written.

                                     EASTMAN KODAK COMPANY

                                     By: _______________________________________
                                           Landlord               Vice President

                                     GENENCOR INTERNATIONAL, INC.

                                     By: _______________________________________
                                           Tenant       Executive Vice President

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00011-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00011-of-00352.parquet"}]]