Document:

EX-10.15

 Exhibit 10.15 

Execution Copy 
 [*]
THE CONFIDENTIAL PORTION HAS BEEN OMITTED PURSUANT TO A REQUEST FOR CONFIDENTIAL 
 TREATMENT AND THE OMITTED MATERIAL HAS BEEN FILED
SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION. 
 Dated 31 July 2013 

EXPLORER NEW BUILD, LLC 
 as
Borrower 
 – and – 

THE BANKS AND FINANCIAL INSTITUTIONS 

listed in Schedule 1 
 as
Lenders 
 – and – 

CRÉDIT AGRICOLE CORPORATE AND INVESTMENT BANK 

SOCIÉTÉ GÉNÉRALE 

HSBC BANK PLC 
 KFW IPEX
BANK GMBH 
 as Joint Mandated Lead Arrangers 

– and– 
 CRÉDIT
AGRICOLE CORPORATE AND INVESTMENT BANK 
 as Agent 

and SACE Agent 
 – and–

 CRÉDIT AGRICOLE CORPORATE AND INVESTMENT BANK 

as Security Trustee 
 LOAN
AGREEMENT 
 relating to the part financing of the 738 passenger cruise ship 

newbuilding presently designated as 

Hull No. 6250 at Fincantieri-Cantieri Navali Italiani S.p.A 

 Execution Copy 
  

							
	 	 	Index	  	 	 
	Clause	 	 	  	Page	 
			
	1	 	 Interpretation
	  	 	2	  
			
	2	 	 Facility
	  	 	22	  
			
	3	 	 Conditions Precedent
	  	 	24	  
			
	4	 	 Drawdown
	  	 	30	  
			
	5	 	 Repayment
	  	 	32	  
			
	6	 	 Interest
	  	 	32	  
			
	7	 	 Interest Periods
	  	 	36	  
			
	8	 	 SACE Premium and Italian Authorities
	  	 	36	  
			
	9	 	 Fees
	  	 	37	  
			
	10	 	 Taxes, Increased Costs, Costs and Related Charges
	  	 	38	  
			
	11	 	 Representations and Warranties
	  	 	44	  
			
	12	 	 General Undertakings
	  	 	49	  
			
	13	 	 Ship Undertakings
	  	 	54	  
			
	14	 	 Insurance Undertakings
	  	 	61	  
			
	15	 	 Security Value Maintenance
	  	 	64	  
			
	16	 	 Cancellation, Prepayment and Mandatory Prepayment
	  	 	65	  
			
	17	 	 Interest on Late Payments
	  	 	67	  
			
	18	 	 Events of Default
	  	 	68	  
			
	19	 	 Application of Sums Received
	  	 	72	  
			
	20	 	 Indemnities
	  	 	73	  
			
	21	 	 Illegality, etc.
	  	 	75	  
			
	22	 	 Set-Off
	  	 	76	  
			
	23	 	 Changes to the Lenders
	  	 	77	  
			
	24	 	 Changes to the Obligors
	  	 	81	  
			
	25	 	 Role of the Agent and the Joint Mandated Lead Arrangers
	  	 	81	  
			
	26	 	 The Security Trustee
	  	 	87	  
			
	27	 	 Conduct of Business by the Creditor Parties
	  	 	97	  
			
	28	 	 Sharing Among the Creditor Parties
	  	 	97	  
			
	29	 	 Payment Mechanics
	  	 	98	  
			
	30	 	 Variations and Waivers
	  	 	100	  
			
	31	 	 Notices
	  	 	102	  
			
	32	 	 Confidentiality
	  	 	104	  
			
	33	 	 Supplemental
	  	 	106	  
			
	34	 	 Governing Law
	  	 	107	  
			
	35	 	 Enforcement
	  	 	107	  
		
	Schedule 1 Lenders and Commitments	  	 	108	  
		
	Schedule 2 Form of Drawdown Notice	  	 	109	  
		
	Schedule 3 Documents to be produced by the Builder to the Agent on Delivery	  	 	110	  
		
	Schedule 4 Form of Transfer Certificate	  	 	111	  
		
	Schedule 5 Qualifying Certificate	  	 	115	  
		
	Execution Pages	  	 	117	  

 THIS AGREEMENT is made on 31 July 2013 

PARTIES 
  

	(1)	EXPLORER NEW BUILD, LLC, a limited liability company formed in the state of Delaware whose registered office is at Corporation Service Company, 2711 Centerville Road, Suite 400, Wilmington, Delaware, 19808 United
States of America as borrower (the “Borrower”); 

  

	(2)	THE BANKS AND FINANCIAL INSTITUTIONS as lenders (the “Lenders”); 

  

	(3)	CRÉDIT AGRICOLE CORPORATE AND INVESTMENT BANK, SOCIÉTÉ GÉNÉRALE, KFW IPEX-BANK GMBH and HSBC BANK PLC as joint mandated lead arrangers (the “Joint Mandated
Lead Arrangers”); 

  

	(4)	CRÉDIT AGRICOLE CORPORATE AND INVESTMENT BANK, as agent and SACE agent (the “Agent”) and (the “SACE Agent”); and 

 

	(5)	CRÉDIT AGRICOLE CORPORATE AND INVESTMENT BANK, as the security trustee (the “Security Trustee”). 

BACKGROUND 
  

	(A)	By a memorandum of agreement dated October 12th, 2012 (the “MOA”) (as amended from time to time) entered into between (i) Fincantieri - Cantieri Navali Italiani SpA, a company incorporated in
Italy with registered office in Trieste, via Genova, 1, and having fiscal code 00397130584 (the “Builder”) and (ii) Prestige Cruise Holdings Inc. and a shipbuilding contract dated 21 June 2013 (together with the MOA, the
“Shipbuilding Contract”) entered into between (i) the Builder and (ii) the Borrower, the Builder has agreed to design, construct and deliver, and the Borrower has agreed to purchase, a 738 passenger cruise ship currently
having hull number 6250 as more particularly described in the Shipbuilding Contract to be delivered on 30 June 2016 subject to any adjustments of such delivery date in accordance with the Shipbuilding Contract. 

 

	(B)	The total price payable by the Borrower to the Builder under the Shipbuilding Contract is EUR 343,000,000 (the “Initial Contract Price”) payable on the following terms: 

 

	(i)	as to [*] %, being EUR [*], by an initial payment which is to be within 5 Business Days after the effective date of the Shipbuilding Contract in accordance with Article 10.1(A) of the Shipbuilding Contract;

  

	(ii)	as to [*]%, being EUR [*], on the later of the date of commencement of steel cutting and the date falling 24 months prior to the Delivery Date; 

 

	(iii)	as to [*]%, being EUR [*], on the later of keel laying and the date falling 12 months prior to the Delivery Date; 

  

	(iv)	as to [*]%, being EUR [*], on the later of float out and the date falling 9 months prior to the Delivery Date; and 

  

	(v)	as to [*]%, being EUR [*], on delivery of the Ship, 

 as each such event is described in the Shipbuilding
Contract. 
  

	(C)	 The Initial Contract Price may be (i) increased or decreased from time to time under Article 24 of the Shipbuilding Contract in the event that
the Borrower requests, and the Builder agrees, modifications to the specification or plans constituting a part of the Shipbuilding Contract or in the event that, subsequent to the date of the Shipbuilding Contract, variations are made to its
provisions compliance with which is compulsory, the net cost of all such 

  
 1 

	 	
variations being payable on the Delivery Date (the “Change Orders”); and (ii) decreased at delivery of the Ship under Articles 13, 14, 16, 17, 19 and 20 of the Shipbuilding
Contract (in aggregate the “Liquidated Damages”) or by mutual agreement between the parties (the Initial Contract Price adjusted as aforesaid being the “Final Contract Price”). 

 

	(D)	The Lenders have agreed to make available to the Borrower a Dollar loan facility for the purpose of assisting the Borrower in financing, subject to exchange rate fluctuations, up to 80% of the Final Contract Price and
100% of the SACE Premium. 

 OPERATIVE PROVISIONS 

1 INTERPRETATION 
  

	1.1	Definitions 

 Subject to Clause 1.5 (General Interpretation), in this Agreement: 

“Affiliate” means in relation to any person, a Subsidiary of that person or a Holding Company of that person or any other Subsidiary of that
Holding Company. 
 “Affected Lender” has the meaning given in Clause 6.5 (Market disruption). 

“Agent” means Crédit Agricole Corporate and Investment Bank, a French “société anonyme”, having a share
capital of EUR 7,254,575,271 and its registered office located at 9, Quai du Président Paul Doumer, 92920 Paris La Défense cedex, France, registered under the n° Siren 304 187 701 at the Registre du Commerce et des
Sociétés of Nanterre or any successor of it appointed under Clause 25 (Role of the Agent and the Joint Mandated Lead Arrangers). 

“Annex VI” means Annex VI (Regulations for the Prevention of Air Pollution from Ships) to the International Convention for the Prevention of
Pollution from Ships 1973 (as modified in 1978 and 1997, 2005, 2007, 2008, 2010 and 2012). 
 “Approved Broker” means Clarkson PLC, Barry
Rogliano Salles, RS Platou ASA, Fearnleys, Rocca & Partners or such other Shipbroker or ship valuer experienced in valuing cruise ships nominated by the Borrower and approved by the Agent and SACE. 

“Approved Flag” means the Marshall Islands flag, the Bahamas flag or such other flag as the Agent may, with the authorisation of the Majority
Lenders and SACE, approve from time to time. 
 “Approved Manager” means the Borrower, Seven Seas, Prestige Cruise Services Inc., or any
other company (whether or not a member of the Group) which the Agent may, with the authorisation of the Majority Lenders, approve from time to time as the manager of the Ship. 

“Approved Manager’s Undertaking” means, in the event that the Approved Manager is a company other than the Borrower (or Seven Seas, as
bareboat charterer), a letter of undertaking executed or to be executed by the Approved Manager in favour of the Agent, which will include, without limitation, an agreement by the Approved Manager to subordinate its rights against the Ship and the
Borrower to the rights of the Secured Parties under the Finance Documents, in the agreed form. 
 “Availability Period” means the period
commencing on the date of this Agreement and ending on: 
  

	(a)	the earlier to occur of (i) the Delivery Date and (ii) 25 February 2017 (or such later date as the Agent may, with the authorisation of the Lenders, agree with the Borrower); or 

 

	(b)	if earlier, the date on which the Total Commitments are fully borrowed, cancelled or terminated. 

  
 2 

 “Base Rate” means one Euro for [*] Dollars. 

“Builder” has the meaning given in Recital (A). 

“Business Day” means a day (other than a Saturday or a Sunday) on which banks are open in London, Frankfurt, Rome and Paris and, in relation
to any payment to be made to the Builder, Milan and, in respect of a day on which a payment is required to be made under a Finance Document, also in New York City. 

“Certified Copy” means in relation to any document delivered or issued by or on behalf of any company, a copy of such document certified as a
true, complete and up-to-date copy of the original by any of the directors or the secretary or assistant secretary or any attorney-in-fact for the time being of that company. 

“Charged Property” means all of the assets which from time to time are, or are expressed to be, the subject of Security Interests pursuant to
the Finance Documents. 
 “CIRR” (Commercial Interest Reference Rate) means 2.13% per annum or any other CIRR rate being the fixed
rate for medium and long term export credits in Dollars applicable to the financing of the Ship according to the Organisation for Economic Co-operation and Development rules as determined by the competent Italian Authorities. 

“CISADA” means the United States Comprehensive Iran Sanctions, Accountability and Divestment Act of 2010 as it applies to non-US persons.

 “Code” means the United States Internal Revenue Code of 1986. 

“Commitment” means, in relation to a Lender, the percentage of the Maximum Loan Amount set opposite its name in (Lenders and
Commitments), or, as the case may require, the amount specified in the relevant Transfer Certificate, as that amount may be reduced, cancelled or terminated in accordance with this Agreement (and “Total Commitments” means the
aggregate of the Commitments of all the Lenders). 
 “Compliance Certificate” has the meaning given to the term “Compliance
Certificate” in the Prestige Holdings Guarantee and the Seven Seas Guarantee. 
 “Confidential Information” means all information
relating to any Obligor, the Group, the Finance Documents or the Loan of which a Creditor Party becomes aware in its capacity as, or for the purpose of becoming, a Creditor Party or which is received by a Creditor Party in relation to, or for the
purpose of becoming a Creditor Party under, the Finance Documents or the Loan from either: 
  

	(a)	any member of the Group or any of its advisers; or 

  

	(b)	another Creditor Party, if the information was obtained by that Creditor Party directly or indirectly from any member of the Group or any of its advisers, 

in whatever form, and includes information given orally and any document, electronic file or any other way of representing or recording information which
contains or is derived or copied from such information but excludes information that: 
  

	(i)	is or becomes public information other than as a direct or indirect result of any breach by that Creditor Party of Clause 32 (Confidentiality)); or 

  
 3 

	(ii)	is identified in writing at the time of delivery as non-confidential by any member of the Group or any of its advisers; or 

  

	(iii)	is known by that Creditor Party before the date the information is disclosed to it in accordance with paragraphs (a) or (b) above or is lawfully obtained by that Creditor Party after that date, from a source
which is, as far as that Creditor Party is aware, unconnected with the Group and which, in either case, as far as that Creditor Party is aware, has not been obtained in breach of, and is not otherwise subject to, any obligation of confidentiality.

 “Confidentiality Undertaking” means a confidentiality undertaking in substantially the appropriate form recommended by the
LMA from time to time or in any other form agreed between the Borrower and the Agent. 
 “Contribution” means, in relation to a Lender, the
part of the Loan which is owing to that Lender. 
 “Conversion Rate” means the rate determined by the Agent on the Conversion Rate Fixing
Date and notified to the Borrower as being the lower of: 
  

	(a)	the Base Rate; or 

  

	(b)	the FOREX Contracts Weighted Average Rate. 

 “Conversion Rate Fixing Date” means the date
falling [*] days before the Intended Delivery Date. 
 “Corresponding Debt” means any amount, other than any Parallel Debt, which an
Obligor owes to a Creditor Party under or in connection with the Finance Documents. 
 “Creditor Party” means the Agent, the Security
Trustee, the SACE Agent, the Joint Mandated Lead Arrangers or any Lender, whether as at the date of this Agreement or at any later time. 

“Delivery Date” means the date and time of delivery of the Ship by the Builder to the Borrower as stated in the Protocol of Delivery and
Acceptance. 
 “Document of Compliance” has the meaning given to it in the ISM Code. 

“Dollar Equivalent” means such amount in Dollars as is calculated by the Agent on the Conversion Rate Fixing Date to be the equivalent of an
amount in Euro at the Conversion Rate. 
 “Dollars” and “$” means the lawful currency for the time being of the United
States of America. 
 “Drawdown Date” means the date on which the Loan is drawn down and applied in accordance with Clause 2
(Facility). 
 “Drawdown Notice” means a notice in the form set out in (Form of Drawdown Notice) (or in any other form which
the Agent approves or reasonably requires). 
 “Earnings” means all moneys whatsoever which are now, or later become, payable (actually or
contingently) to the Borrower or Seven Seas (as bareboat charterer) and which arise out of the use or operation of the Ship, including (but not limited to): 
  

	(a)	all freight, hire, fare and passage moneys, compensation payable to the Borrower or the Agent in the event of requisition of the Ship for hire, remuneration for salvage and towage services, demurrage and detention
moneys and damages for breach (or payments for variation or termination) of any charterparty or other contract for the employment of the Ship; 

  
 4 

	(b)	all moneys which are at any time payable under Insurances in respect of loss of earnings; and 

  

	(c)	all moneys which are at any time payable to the Borrower in respect of the general average contribution; 

  

	(d)	if and whenever the Ship is employed on terms whereby any moneys falling within paragraphs (a) or (b) above are pooled or shared with any other person, that proportion of the net receipts of the relevant
pooling or sharing arrangement which is attributable to the Ship. 

 “Eligible Amount” means 80% of the lesser of: 

 

	(a)	the Dollar Equivalent of EUR355,005,000; and 

  

	(b)	the Dollar Equivalent of the Final Contract Price. 

 “Environmental Approval” means any
present or future permit, ruling, variance or other Authorisation required under Environmental Laws. 
 “Environmental Claim” means any
claim by any governmental, judicial or regulatory authority or any other person which arises out of an Environmental Incident or an alleged Environmental Incident or which relates to any Environmental Law and, for this purpose, “claim”
includes a claim for damages, compensation, contribution, injury, fines, losses and penalties or any other payment of any kind, including in relation to clean-up and removal, whether or not similar to the foregoing; an order or direction to take, or
not to take, certain action or to desist from or suspend certain action; and any form of enforcement or regulatory action, including the arrest or attachment of any asset. 

“Environmental Incident” means: 
  

	(a)	any release, emission, spill or discharge into the Ship or into or upon the air, sea, land or soils (including the seabed) or surface water of Environmentally Sensitive Material within or from the Ship; or

  

	(b)	any incident in which Environmentally Sensitive Material is released, emitted, spilled or discharged into or upon the air, sea, land or soils (including the seabed) or surface water from a vessel other than the Ship and
which involves a collision between the Ship and such other vessel or some other incident of navigation or operation, in either case, in connection with which the Ship is actually or potentially liable to be arrested, attached, detained or injuncted
and/or the Ship and/or any Obligor and/or any operator or manager of the Ship is at fault or allegedly at fault or otherwise liable to any legal or administrative action; or 

 

	(c)	any other incident in which Environmentally Sensitive Material is released, emitted, spilled or discharged into or upon the air, sea, land or soils (including the seabed) or surface water otherwise than from the Ship
and in connection with which the Ship is actually or potentially liable to be arrested and/or where any Obligor and/or any operator or manager of the Ship is at fault or allegedly at fault or otherwise liable to any legal or administrative action,
other than in accordance with an Environmental Approval. 

 “Environmental Law” means any present or future law relating to
pollution or protection of human health or the environment, to conditions in the workplace, to the carriage, generation, handling, storage, use, release or spillage of Environmentally Sensitive Material or to actual or threatened releases of
Environmentally Sensitive Material. 

  
 5 

 “Environmentally Sensitive Material” means and includes all contaminants, oil, oil products,
toxic substances and any other substance (including any chemical, gas or other hazardous or noxious substance) which is (or is capable of being or becoming) polluting, toxic or hazardous. 

“Euro” and “EUR” means the single currency of the Participating Member States. 

“Event of Default” means any of the events or circumstances described in Clause 18.1 (Events of Default). 

“Existing Indebtedness” means (a) Loan Agreement, dated as of July 18, 2008, by and among Marina New Build, LLC, as Borrower, the
banks and financial institutions party thereto, Crédit Agricole Corporate and Investment Bank (formerly Calyon) and Société Générale, as Mandated Lead Arrangers, and Crédit Agricole Corporate and Investment
Bank, as Agent and as SACE Agent (as amended from time to time); (b) Loan Agreement, dated as of July 18, 2008, by and among Riviera New Build, LLC, as Borrower, the banks and financial institutions party thereto, Crédit Agricole
Corporate and Investment Bank (formerly Calyon) and Société Générale, as Mandated Lead Arrangers, and Crédit Agricole Corporate and Investment Bank, as Agent and as SACE Agent (as amended from time to time);
(c) Credit Agreement, dated as of July 2, 2013, among Oceania Cruises, Inc., OCI Finance Corp., as Borrowers, the banks and financial institutions party thereto, Deutsche Bank AG, New York Branch, as administrative agent, as collateral
agent and as mortgage trustee, Deutsche Bank Securities Inc., Barclays Bank Plc and UBS Securities LLC as co-syndication agents, HSBC Securities (USA) Inc. and Credit Agricole Corporate and Investment Bank as co-documentation agents, Barclays Bank
Plc, UBS Securities LLC, HSBC Securities (USA) INC. and Credit Agricole Corporate and Investment Bank, as joint bookrunners, Deutsche Bank Securities Inc., Barclays Bank Plc and Ubs Securities LLC, as joint lead arrangers; (d) Credit Agreement,
dated as of August 21, 2012 and amended on February 1, 2013, among Classic Cruises, LLC, Classic Cruises II, LLC, Seven Seas Cruises S. De R.L., a Panamanian sociedad de responsibilidad limitada, SSC Finance Corp., as Borrowers, Deutsche
Bank Ag, New York Branch, as Administrative Agent and as Collateral Agent, and each lender from time to time party thereto; and (e) $225,000,000 of 9.125% Senior Secured Notes due 2019 and issued under that certain indenture dated as of
May 19, 2011, by and among Seven Seas Cruises S. de R.L., as issuer; Celtic Pacific (UK) Two Limited; Supplystill Limited; Prestige Cruise Services (Europe) Limited (f/k/a Regent Seven Seas Cruises UK Limited); Celtic Pacific (UK) Limited; SSC
(France) LLC; Mariner, LLC, each of the foregoing (other than the Issuer) as subsidiary guarantors; Wilmington Trust, National Association (successor by merger to Wilmington Trust FSB), as Trustee and Collateral Agent and any secured hedges in
connection with the foregoing. 
 “Exporter Declaration” means a declaration in the form required by SIMEST at the relevant time duly
signed by an authorised signatory of the Builder. 
 “External Management Agreement” means, in the event that the Approved Manager is not a
member of the Group, the management agreement entered or to be entered into between the Borrower and the Approved Manager with respect to the Ship on terms reasonably acceptable to the Majority Lenders. 

“Facility Office” means the office or offices notified by a Lender to the Agent in writing on or before the date it becomes a Lender (or,
following that date, by not less than five (5) Business Days’ written notice) as the office or offices through which it will perform its obligations under this Agreement. 

  
 6 

 “FATCA” means: 
  

	(a)	sections 1471 to 1474 of the Code or any associated regulations or other official guidance; 

  

	(b)	any treaty, law, regulation or other official guidance enacted in any other jurisdiction, or relating to an intergovernmental agreement between the US and any other jurisdiction, which (in either case) facilitates the
implementation of paragraph (a) above; or 

  

	(c)	any agreement pursuant to the implementation of paragraphs (a) or (b) above with the US Internal Revenue Service, the US government or any governmental or taxation authority in any other jurisdiction.

 “FATCA Application Date” means: 
  

	(a)	in relation to a “withholdable payment” described in section 1473(1)(A)(i) of the Code (which relates to payments of interest and certain other payments from sources within the US), 1 July 2014;

  

	(b)	in relation to a “withholdable payment” described in section 1473(1)(A)(ii) of the Code (which relates to “gross proceeds” from the disposition of property of a type that can produce interest from
sources within the US), 1 January 2017; or 

  

	(c)	in relation to a “passthru payment” described in section 1471(d)(7) of the Code not falling within paragraphs (a) or (b) above, 1 January 2017, 

or, in each case, such other date from which such payment may become subject to a deduction or withholding required by FATCA as a result of any change in
FATCA after the date of this Agreement. 
 “FATCA Deduction” means a deduction or withholding from a payment under a Finance Document
required by FATCA. 
 “FATCA Exempt Party” means a Party that is entitled to receive payments free from any FATCA Deduction. 

“FATCA Protected Lender” means any Lender irrevocably designated as a FATCA Protected Lender by the Borrower by notice to that Lender and the
Agent at least six months prior to the earliest FATCA Application Date for a payment by a Party to that Lender (or to the Agent for the account of that Lender). 

“Fee Letter” means any letter dated on or about the date of this Agreement between the SACE Agent and the Borrower setting out the fees
referred to in Clause 9.1(d) (Fees). 
 “Finance Documents” means: 

 

	(a)	this Agreement; 

  

	(b)	any Fee Letter; 

  

	(c)	the Guarantees; 

  

	(d)	the Tripartite General Assignment; 

  

	(e)	the Mortgage; 

  

	(f)	the Post-Delivery Assignment; 

  
 7 

	(g)	the Limited Liability Company Interests Security Deed; 

  

	(h)	the Approved Manager’s Undertaking; 

  

	(i)	the SACE Reimbursement Agreement; 

  

	(j)	any Transfer Certificate; 

  

	(k)	any other document (whether creating a Security Interest or not) which is executed as security for, or for the purpose of establishing any priority or subordination arrangement in relation to, the Secured Liabilities;
and 

  

	(l)	any other document (whether creating a Security Interest or not) which is designated as a Finance Document by agreement between the Borrower, SACE and the Agent. 

“Final Contract Price” has the meaning given in Recital (C). 

“Financial Indebtedness” means, in relation to a person (the “debtor”), a liability of the debtor: 

 

	(a)	for principal, interest or any other sum payable in respect of any moneys borrowed or raised by the debtor; 

  

	(b)	under any loan stock, bond, note or other security issued by the debtor; 

  

	(c)	under any acceptance credit, guarantee or letter of credit facility made available to the debtor; 

  

	(d)	under a financial lease, a deferred purchase consideration arrangement or any other agreement having the commercial effect of a borrowing or raising of money by the debtor; 

 

	(e)	under any foreign exchange transaction, any interest or currency swap or any other kind of derivative transaction entered into by the debtor or, if the agreement under which any such transaction is entered into requires
netting of mutual liabilities, the liability of the debtor for the net amount; 

  

	(f)	under a guarantee, indemnity or similar obligation entered into by the debtor in respect of a liability of another person which would fall within paragraphs (a) to (e) if the references to the debtor referred
to the other person; or 

  

	(g)	receivables sold or discounted (other than receivables to the extent they are sold on a non-recourse basis). 

“First Instalment” means the first instalment of the SACE Premium as more particularly described in Clause 8.1(a). 

“Fixed Interest Rate” means, in respect of any Interest Period, the rate per annum determined by the Agent to be the aggregate of: 

 

	(a)	the Margin; and 

  

	(b)	the CIRR. 

 “Floating Interest Rate” means, in respect of any Interest Period, the rate per
annum determined by the Agent to be the aggregate of: 
  

	(a)	the Margin; and 

  

	(b)	LIBOR for the relevant period. 

  
 8 

 “FOREX Contracts” means each actual purchase contract, spot or forward contract and any other
contract, such as an option or collar arrangement, which is entered into in the foreign exchange markets for the acquisition of Euro intended to pay the delivery instalment under the Shipbuilding Contract, which: 

 

	(a)	matures not later than the Intended Delivery Date, provided that option arrangements may mature up to one month after such date if at the time they are entered into there exists a reasonable uncertainty as to the date
on which the Ship will be delivered; 

  

	(b)	is entered into by the Borrower or either Guarantor or a combination of the foregoing not later than two (2) days before the Conversion Rate Fixing Date so that the Borrower, directly or through a Guarantor,
purchases or may purchase Euro with Dollars at a pre-agreed rate; and 

  

	(c)	is notified to the Agent within twenty (20) days of its execution but in any event no later than the day preceding the Conversion Rate Fixing Date, with a Certified Copy of each such contract being delivered to the
Agent at such time. 

 “FOREX Contracts Weighted Average Rate” means the rate determined by the Agent on the Conversion Rate
Fixing Date in accordance with the following principles which (inter alia) are intended to take into account any maturity mismatch between the maturity of the FOREX Contracts and the Intended Delivery Date as well as FOREX Contracts that are unwound
as part of the hedging strategy of the Borrower: 
  

	(a)	FOREX Contracts that are spot or forward foreign exchange contracts, if any, shall be valued at the contract value (taking into account any rescheduling); 

 

	(b)	the difference between the Euro amount available under (i) above and the Euro amount balance payable to the Builder on the Delivery Date is assumed to be purchased at the official daily fixing rate of the European
Central Bank for the purchase of Euro with Dollars as displayed on “Reuters Page ECB 37” (or such other pages as may replace that page on that service or a successor service) at or around 2 p.m. (Paris time) on the Conversion Rate Fixing
Date; 

  

	(c)	any FOREX Contract which is an option or collar arrangement and is not unwound at the Conversion Rate Fixing Date will be marked to market and the resulting profit or loss shall reduce or increase the Dollar
countervalue of the purchased Euro; 

  

	(d)	any FOREX Contract which is an option or collar arrangement and is sold or purchased back at the time FOREX Contract(s) are entered into for an identical Euro amount shall be accounted for the net premium cost or
profit, as the case may be. 

 Any marked to market valuation, as required in (c), shall be performed by Crédit Agricole Corporate and
Investment Bank’s dedicated desk in accordance with market practices. The Borrower shall have the right to request indicative valuations from time to time prior to the Conversion Rate Fixing Date. 

“GAAP” means generally accepted accounting principles in the United States of America consistently applied (or, if not consistently applied,
accompanied by details of the inconsistencies) including, without limitation, those set forth in the opinion and pronouncements of the Accounting Principles Board of the American Institute of Certified Public Accountants and statements and
pronouncements of the Financial Accounting Standards Board. 

  
 9 

 “Gross Negligence” means any act or omission, whether deliberate or not, which in the
circumstances (including both the probability and seriousness of the consequences likely to result) would reasonably be regarded by those familiar with the nature of the activity in question and with the surrounding circumstances, as amounting to
the reckless disregard of, or serious indifference to, the consequences, being in any case more than a negligent failure to exercise proper skill and care. 

“Group” means Prestige Holdings and its Subsidiaries. 

“Guarantees” means the Seven Seas Guarantee and the Prestige Holdings Guarantee. 

“Guarantors” means Seven Seas and Prestige Holdings. 

“Holding Company” means, in relation to a person, any other person in respect of which it is a Subsidiary; 

“IAPPC” means a valid international air pollution prevention certificate for the Ship issued under Annex VI. 

“Illicit Origin” means any origin which is illicit or fraudulent including, without limitation, drug trafficking, corruption, organised
criminal activities, terrorism, money laundering or fraud. 
 “Initial Contract Price” has the meaning given in Recital (B). 

“Insurances” means: 
  

	(a)	all policies and contracts of insurance, including entries of the Ship in any protection and indemnity or war risks association, which are effected in respect of the Ship, its Earnings or otherwise in relation to it;
and 

  

	(b)	all rights and other assets relating to, or derived from any of such policies, contracts or entries, including any rights to a return of a premium. 

“Intended Delivery Date” means 30 June 2016 (the date on which the Ship will be ready for delivery pursuant to the Shipbuilding Contract
as at the date of this Agreement) or any other date notified by the Borrower to the Agent in accordance with Clauses 3.5(a)(i) or 3.7(c) as being the date on which the Builder and the Borrower have agreed that the Ship will be ready for delivery
pursuant to the Shipbuilding Contract. 
 “Interest Make-up Agreement” means an interest make up agreement (Capitolato) to be
entered into between SIMEST and the Agent on behalf of the Lenders and in form and substance acceptable to the Joint Mandated Lead Arrangers, whereby, inter alia, the return to the Lenders on the Loan made hereunder will be supplemented by SIMEST so
that it equals that which the Lenders would have received if interest were payable on the Loan at LIBOR plus the Margin. 
 “Interest
Period” means a period determined in accordance with Clause 7 (Interest Periods). 
 “ISM Code” means the International
Safety Management Code for the safe operation of ships and for pollution prevention (including the guidelines on its implementation), adopted by the International Maritime Organisation as the same may be amended or supplemented from time to time.

 “ISPS Code” means the International Ship and Port Facility Security (ISPS) Code adopted by the International Maritime Organisation (IMO)
Diplomatic Conference of December 2002, as the same may be amended or supplemented from time to time. 

  
 10 

 “Italian Authorities” means SACE and/or SIMEST and any other relevant Italian authorities
involved in the implementation of the Loan. 
 “Lender” means a bank, financial institution, trust, fund or other entity listed in 0
(Lenders and Commitments) and acting through its Facility Office or its transferee, successor or assign. 
 “LIBOR” means, in
relation to a particular period, the rate determined by the Agent to be that at which deposits of Dollars in amounts comparable with the amount for which LIBOR is to be determined and for a period equivalent to such period are being offered in the
London interbank eurocurrency market at or about 11 a.m. (London time) on the Quotation Date for such period as displayed on the “Reuters Page LIBOR 01 or LIBOR 02” of the Reuters screen (or any replacement Reuters page which displays that
rate) or on the appropriate page of such other information service which publishes that rate from time to time in place of Reuters (and if such page or service ceases to be available, the Agent may specify another page or service displaying the
relevant rate after consultation with the Borrower), Provided that if on such date no such rate is so displayed, LIBOR for such period shall be the rate quoted to the Agent by the Lenders at the request of the Agent as the Lenders’
offered rate for deposits of Dollars in an amount approximately equal to the amount in relation to which LIBOR is to be determined for a period equivalent to such period to prime banks in the London interbank eurocurrency market at or about 11 a.m.
(London time) on the Quotation Date for such period and provided further that, if the rate displayed on the relevant page is less than zero, LIBOR shall be deemed to be zero. 

“Limited Liability Company Interests Security Deed” means a security pledge in relation to the limited liability company interests of the
Borrower executed or to be executed by Seven Seas in favour of the Security Trustee in the agreed form. 
 “Loan” means the principal
amount for the time being outstanding under this Agreement. 
 “Majority Lenders” means: 

 

	(a)	before the Loan has been made, Lenders whose Commitments total [*]per cent. of the Total Commitments; and 

  

	(b)	after the Loan has been made, Lenders whose Contributions total [*]per cent. of the Loan. 

“Margin” means: 
  

	(a)	in relation to the Fixed Interest Rate one point thirty per cent. (1.30%) per annum; and 

  

	(b)	in relation to the Floating Interest Rate two point eighty per cent. (2.80%) per annum. 

“Maritime Registry” means the maritime registry which the Borrower will specify to the Lenders no later than three (3) months before the
Intended Delivery Date, being that of the Marshall Islands, Bahamas or such other registry as the Agent may, with the authorisation of the Majority Lenders and SACE, approve. 

“Material Adverse Effect” means the occurrence of any event or circumstance which reasonably would be expected to have a material adverse
effect on: 
  

	(a)	the business, operations, property, condition (financial or otherwise) of any Obligor or the Group as a whole; or 

  

	(b)	the ability of any Obligor to perform its obligations under any Finance Document; or 

  

	(c)	the validity or enforceability of, or the effectiveness or ranking of any Security Interest granted or intended to be granted pursuant to any of, the Finance Documents or the rights or remedies of any Secured Party
under any of the Finance Documents. 

  
 11 

 “Maximum Loan Amount” means the aggregate of: 

 

	(a)	the Dollar Equivalent of Euro [*]; 

  

	(b)	[*]% of the First Instalment of the SACE Premium to be paid by the Borrower direct to SACE on or before [*]days following the issuance of the SACE Insurance Policy; and 

 

	(c)	[*]% of the Second Instalment of the SACE Premium payable on the Drawdown Date, 

 Provided that such
amount shall not, at any time, exceed US$440,321,649. 
 “Mortgage” means the first priority mortgage on the Ship acceptable for
registration on the Approved Flag and, if applicable, deed of covenant, executed or to be executed by the Borrower in favour of the Security Trustee in the agreed form. 

“Negotiation Period” has the meaning given in Clause 6.8 (Negotiation of alternative rate of interest). 

“Obligors” means the Borrower, the Guarantors and (in the event that the Approved Manager is a member of the Group) the Approved Manager.

 “OFAC” means the Office of Foreign Assets Control of the United States Department of the Treasury. 

“Overnight LIBOR” means, on any date, the London interbank offered rate, being the day to day rate at which Dollars are offered to prime
banks in the London interbank market and published by the British Bankers’ Association at or about 11.00 a.m. London time on page LIBOR01 of the Reuters screen. If the agreed page is replaced or the service ceases to be available, the Agent may
specify another page or service displaying the appropriate rate after consultation with the Borrower. 
 “Parallel Debt” means any amount
which an Obligor owes to the Security Trustee under Clause 26.2 (Parallel Debt (Covenant to pay the Security Trustee)). 
 “Participating
Member State” means any member state of the European Union that adopts or has adopted the euro as its lawful currency in accordance with legislation of the European Union relating to Economic and Monetary Union. 

“Party” means a party to this Agreement from time to time. 

“Permitted Security Interests” means: 
  

	(a)	in the case of the Borrower, 

  

	(i)	any of the Security Interests referred to in paragraph (b)(ii)(A) below, and 

  

	(ii)	any of the Security Interests referred to in paragraphs (b)(ii)(B), (b)(ii)(C), (b)(ii)(E), (b)(ii)(H) and (b)(ii)(I) below if, by reason of any chartering or management arrangements for the Ship approved by the Agent
pursuant to the provisions of this Agreement, such Security Interests are created by the Borrower in the case of paragraphs (b)(ii)(C) or (b)(ii)(E) or incurred by the Borrower in the case of paragraphs (b)(ii)(B), (b)(ii)(H) or (b)(ii)(I); and

  
 12 

	(b)	in the case of a Guarantor, 

  

	(i)	any of the Security Interests referred to in paragraphs (ii)(A), (ii)(D), (ii)(F) and (ii)(G) below, and 

  

	(ii)	any of the Security Interests referred to in paragraphs (C), (E), (H) and (I) below if, by reason of any chartering or management arrangements for the Ship approved by the Agent pursuant to the provisions of
this Agreement, such Security Interests are created by either Guarantor in the case of paragraphs (C) or (E) or incurred by either Guarantor in the case of paragraphs (H) or (I); 

 

	(A)	any Security Interest created by or pursuant to the Finance Documents and any deposits or other Security Interests placed or incurred in connection with any bond or other surety from time to time provided to the US
Federal Maritime Commission in order to comply with laws, regulations and rules applicable to the operators of passenger vessels operating to or from ports in the United States of America; 

 

	(B)	liens on the Ship up to an aggregate amount at any time not exceeding $[*] for current crew’s wages and salvage and liens incurred in the ordinary course of trading the Ship; 

 

	(C)	any deposits or pledges up to an aggregate amount at any time not exceeding $[*] to secure the performance of bids, tenders, bonds or contracts required in the ordinary course of business; 

 

	(D)	any other Security Interest including in relation to the Existing Indebtedness over the assets of any Obligor other than the Borrower notified by the Borrower or any of the Obligors to the Agent and SACE and accepted by
them prior to the date of this Agreement; 

  

	(E)	(without prejudice to the provisions of Clause 12.13 (Financial Indebtedness and subordination of indebtedness)) liens on assets leased, acquired or upgraded after the date hereof or assets newly constructed or
converted after the date hereof provided that (i) such liens secure Financial Indebtedness otherwise permitted under this Agreement, (ii) such liens are incurred at the time of such lease, acquisition, upgrade, construction or conversion
and (iii) the Financial Indebtedness secured by such liens does not exceed the cost of such upgrade or the cost of such assets acquired or leased; 

  

	(F)	other liens arising in the ordinary course of business of the Group unrelated to Financial Indebtedness and securing obligations not yet delinquent or which are being contested in good faith by appropriate proceedings
and for which adequate reserves have been established provided that (i) the aggregate amount of all cash and the fair market value of all other property subject to such liens as are described in this paragraph (f) above does not exceed
$[*] and (ii) such cash and/or other property is not an asset of the Borrower; 

  

	(G)	subject to the other provisions of this Agreement and the Guarantee, any Security Interest in respect of existing Financial Indebtedness of a person which becomes a Subsidiary of either Guarantor or is merged with or
into either Guarantor or any of their subsidiaries; 

  
 13 

	(H)	liens in favour of credit card companies on unearned customer deposits pursuant to agreements therewith; 

  

	(I)	liens in favour of customers on unearned customer deposits. 

 “Pertinent Document” means: 

 

	(a)	any Finance Document; 

  

	(b)	any policy or contract of insurance contemplated by or referred to in Clause 12 (General Undertakings) or any other provision of this Agreement or another Finance Document; 

 

	(c)	any other document contemplated by or referred to in any Finance Document; and 

  

	(d)	any document which has been or is at any time sent by or to the Agent in contemplation of or in connection with any Finance Document or any policy, contract or document falling within paragraphs (b) or (c).

 “Pertinent Matter” means: 
  

	(a)	any transaction or matter contemplated by, arising out of, or in connection with a Pertinent Document; or 

  

	(b)	any statement relating to a Pertinent Document or to a transaction or matter falling within paragraph (a); 

and covers any such transaction, matter or statement, whether entered into, arising or made at any time before the signing of this Agreement or on or at any
time after that signing. 
 “Post-Delivery Assignment” means an assignment of the rights of the Borrower in respect of the post-delivery
guarantee liability of the Builder under Article 25 of the Shipbuilding Contract executed or to be executed by the Borrower in favour of the Security Trustee in the agreed form. 

“Prestige Holdings” means Prestige Cruise Holdings Inc. a Panamanian sociedad anonima domiciled in Panama whose resident agent is
Arias, Fabrega & Fabrega at Plaza 2000 Building, 16th Floor, 50th Street, Panama, Republic of Panama. 
 “Prestige Holdings
Guarantee” means a guarantee issued or to be issued as provided in Clause 3.2 (No later than the date of this Agreement) by Prestige Holdings in favour of the Security Trustee in the agreed form. 

“Prohibited Payment” means: 
  

	(a)	any offer, gift, payment, promise to pay, commission, fee, loan or other consideration which would constitute bribery or an improper gift or payment under, or a breach of, any laws of the Republic of Italy, England and
Wales, Panama, the United States of America or any other applicable jurisdiction; or 

  

	(b)	any offer, gift, payment, promise to pay, commission, fee, loan or other consideration which would or might constitute bribery within the OECD Convention on Combating Bribery of Foreign Public Officials in International
Business Transactions of 17 December 1997. 

  
 14 

 “Prohibited Person” means any person (whether designated by name or by reason of being included
in a class of persons) against whom Sanctions are directed. 
 “Protocol of Delivery and Acceptance” means the protocol of delivery and
acceptance of the Ship to be signed by the Borrower and the Builder in accordance with Article 8 of the Shipbuilding Contract. 
 “Quotation
Date” means, in relation to any Interest Period (or any period for which an interest rate is to be determined under any provision of a Finance Document), the day which is 2 Business Days before the first day of that period, unless market
practice differs in the Relevant Interbank Market for a currency, in which case the Quotation Date will be determined by the Agent in accordance with market practice in the Relevant Interbank Market (and if quotations would normally be given by
leading banks in the Relevant Interbank Market on more than one day, the Quotation Date will be the last of those days). 
 “Qualifying
Certificate” means the certificate to be issued by the Builder on the Delivery Date and issued to the Agent and copied to the Borrower substantially in the form set out in Schedule 5. 

“Relevant Interbank Market” means the European Interbank Market. 

“Relevant Jurisdiction” means, in relation to an Obligor: 
  

	(a)	its jurisdiction of incorporation; 

  

	(b)	any jurisdiction where any asset subject to, or intended to be subject to, any of the Security Interests created, or intended to be created, under the Finance Documents to which it is a party is situated;

  

	(c)	any jurisdiction where it conducts its business; and 

  

	(d)	the jurisdiction whose laws govern the perfection of any of the Security Interests created, or intended to be created, under the Finance Documents to which it is a party. 

“Repayment Date” means a date on which a repayment is required to be made under Clause 5 (Repayment). 

“Representative” means any delegate, agent, manager, administrator, nominee, attorney, trustee or custodian. 

“Requisition Compensation” includes all compensation or other moneys payable by reason of any act or event such as is referred to in
paragraph (b) of the definition of “Total Loss”. 
 “SACE” means SACE SpA. 

“SACE Agent” means Crédit Agricole Corporate and Investment Bank, a French “société anonyme”, having a share
capital of EUR 7,254,575,271 and its registered office located at 9, Quai du Président Paul Doumer, 92920 Paris La Défense cedex, France, registered under the n° Siren 304 187 701 at the Registre du Commerce et des
Sociétés of Nanterre or any successor of it appointed under Clause 25 (Role of the Agent and the Joint Mandated Lead Arrangers). 

“SACE Insurance Policy” means the insurance policy in respect of this Agreement (which, in all material respects, is not inconsistent with
the commercial terms of this Agreement) to be issued by SACE for the benefit of the Lenders in respect of 95% of the Loan in form and substance satisfactory to the Agent and the Lenders. 

  
 15 

 “SACE Premium” means the amount payable by the Borrower to SACE directly or through the Agent in
two instalments in respect of the SACE Insurance Policy as set out in Clause 8 (SACE Premium and Italian Authorities). 
 “SACE Reimbursement
Agreement” means the reimbursement agreement entered into or to be entered into, as the context may require, between the Borrower, the Guarantors, the Agent and SACE. 

“SACE Required Documents” means in relation to the Drawdown Notice: 
  

	(a)	a duly completed and executed Qualifying Certificate; and 

  

	(b)	each of the other documents, information and other evidence specified in or required to be enclosed with such Qualifying Certificate. 

“Sanctions” means any sanctions, embargoes, freezing provisions, prohibitions or other restrictions relating to trading, doing business,
investment, exporting, financing or making assets available (or other activities similar to or connected with any of the foregoing): 
  

	(a)	imposed by law or regulation of the United Kingdom, the Council of the European Union, the United Nations or its Security Council or imposed by any member state of the European Union or Switzerland; 

 

	(b)	imposed by CISADA or OFAC; or 

  

	(c)	otherwise imposed by any law or regulation, 

 by which any Obligor is bound or to which it is subject or, as
regards a regulation, compliance with which is reasonable in the ordinary course of business of any Obligor. 
 “Second Instalment” means
the second instalment of the SACE Premium as more particularly described in Clause 8.1(b). 
 “Secured Liabilities” means all liabilities
which the Borrower, the Obligors or any of them have, at the date of this Agreement or at any later time or times, under or in connection with any Finance Document or any judgment relating to any Finance Document; and for this purpose, there shall
be disregarded any total or partial discharge of these liabilities, or variation of their terms, which is effected by, or in connection with, any bankruptcy, liquidation, arrangement or other procedure under the insolvency laws of any country. 

“Secured Party” means SACE, the Agent, the Security Trustee, the SACE Agent, the Joint Mandated Lead Arrangers or any Lender whether at the
date of this Agreement or any later time. 
 “Security Interest” means: 

 

	(a)	a mortgage, charge (whether fixed or floating) or pledge, any maritime or other lien, assignment, hypothecation or any other security interest of any kind or other agreement or arrangement having the effect of
conferring security; 

  

	(b)	the security rights of a plaintiff under an action in rem; and 

  

	(c)	any arrangement entered into by a person (A) the effect of which is to place another person (B) in a position which is similar, in economic terms, to the position in which B would have been had he held a
security interest over an asset of A; but this paragraph (c) does not apply to a right of set off or combination of accounts conferred by the standard terms of business of a bank or financial institution. 

  
 16 

 “Security Period” means the period commencing on the date of this Agreement and ending on the
date on which: 
  

	(a)	all amounts which have become due for payment by the Borrower or any Obligor under the Finance Documents have been paid; 

  

	(b)	no amount is owing or has accrued (without yet having become due for payment) under any Finance Document; 

  

	(c)	neither the Borrower nor any other Obligor has any future or contingent liability under Clause 19 (Application of Sums Received) below or any other provision of this Agreement or another Finance Document; and

  

	(d)	the Agent and the Majority Lenders do not consider that there is a significant risk that any payment or transaction under a Finance Document would be set aside, or would have to be reversed or adjusted, in any present
or possible future bankruptcy of the Borrower or an Obligor or in any present or possible future proceeding relating to a Finance Document or any asset covered (or previously covered) by a Security Interest created by a Finance Document.

 “Security Property” means: 
  

	(a)	the Security Interests expressed to be granted in favour of the Security Trustee as trustee for the Secured Parties and all proceeds received or recovered by or on behalf of the Security Trustee under or by virtue of
any Security Interest including any money or other assets which are received or recovered by it as a result of the enforcement or exercise by it of such a Security Interest or right; 

 

	(b)	all obligations expressed to be undertaken by an Obligor to pay amounts in respect of the Secured Liabilities to the Security Trustee as trustee for the Secured Parties and secured by the Security Interests together
with all representations and warranties expressed to be given by an Obligor in favour of the Security Trustee as trustee for the Secured Parties; 

  

	(c)	the Security Trustee’s interest in any turnover trust created under the Finance Documents; 

  

	(d)	any other amounts or property, whether rights, entitlements, choses in action or otherwise, actual or contingent, which the Security Trustee is required by the terms of the Finance Documents to hold as trustee on trust
for the Secured Parties, 

 except: 
  

	(i)	rights intended for the sole benefit of the Security Trustee; and 

  

	(ii)	any moneys or other assets which the Security Trustee has transferred to the Agent or (being entitled to do so) has retained in accordance with the provisions of this Agreement. 

“Security Requirement” means the amount in Dollars (as certified by the Agent whose certificate shall, in the absence of manifest error, be
conclusive and binding on the Borrower and the Agent) which is at any relevant time one hundred per cent (100%) of the Loan. 
 “Security
Trustee” means Crédit Agricole Corporate and Investment Bank, a French “société anonyme”, having a share capital of EUR 7,254,575,271 and its registered office located at 9, Quai du Président Paul
Doumer, 92920 Paris La Défense cedex, France, registered under the n° Siren 304 187 701 at the Registre du Commerce et des Sociétés of Nanterre or any successor of it appointed under Clause 26 (The Security Trustee).

  
 17 

 “Security Value” means the amount in Dollars (as certified by the Agent whose certificate shall,
in the absence of manifest error, be conclusive and binding on the Borrower and the Agent) which, at any relevant time, is the aggregate of (i) the market value of the Ship as most recently determined in accordance with Clause 13.4
(Valuation of the Ship); and (ii) the market value of any additional security for the time being actually provided to the Agent pursuant to Clause 15 (Security Value Maintenance). 

“Servicing Party” means the Agent or the Security Trustee. 

“Seven Seas” means Seven Seas Cruises S. DE R.L., a Panamanian sociédad de responsibilidad limitada domiciled in Panama whose
resident agent is Arias, Fabrega & Fabrega at Plaza 2000 Building, 16th Floor, 50th Street, Panama, Republic of Panama]. 

“Seven Seas Charter” means the bareboat charter of the Ship by the Borrower as owner to the Seven Seas as charterer which shall be entered
into no later than the Delivery Date in the form of draft approved by the Agent before the date of this Agreement with such reasonable changes thereto as the Agent may, with the authority of the Majority Lenders, approve from time to time. 

“Seven Seas Guarantee” means a guarantee issued or to be issued as provided in Clause 3.2 (No later than the date of this Agreement)
by Seven Seas in favour of the Security Trustee in the agreed form. 
 “Ship” means the passenger cruise ship currently designated with
Hull No. 6250 (as more particularly described in the Shipbuilding Contract) to be constructed under the Shipbuilding Contract and to be delivered to, and purchased by, the Borrower and registered in its name under an Approved Flag with the name
“Explorer”. 
 “Shipbuilding Contract” has the meaning given in Recital (A). 

“SIMEST” means Società Italiana per Le Imprese all’Estero - SIMEST Spa, which grants export subsidies in Italy under and
according to the Italian Legislative Decree n. 143/98 and its amendments. 
 “Subsidiary” has the following meaning: 

A company (S) is a subsidiary of another company (P) if: 
  

	(i)	a majority of the issued shares in S (or a majority of the issued shares in S which carry unlimited rights to capital and income distributions) are directly owned by P or are indirectly attributable to P; or

  

	(ii)	P has direct or indirect control over a majority of the voting rights attaching to the issued shares of S; or 

  

	(iii)	P has the direct or indirect power to appoint or remove a majority of the directors of S; or 

  

	(iv)	P otherwise has the direct or indirect power to ensure that the affairs of S are conducted in accordance with the wishes of P; 

and any company of which S is a subsidiary is a parent company of S. 

“Tax” means any tax, levy, impost, duty, assessment, fee, deduction or other charge or withholding of a similar nature imposed by any
governmental authority (including any penalty or interest payable in connection with any failure to pay or any delay in paying any of the same). 

  
 18 

 “Total Loss” means: 
  

	(a)	actual, constructive, compromised, agreed or arranged total loss of the Ship; 

  

	(b)	any expropriation, confiscation, requisition or acquisition of the Ship, whether for full consideration, a consideration less than its proper value, a nominal consideration or without any consideration, which is
effected by any government or official authority or by any person or persons claiming to be or to represent a government or official authority, (excluding a requisition for hire for a fixed period not exceeding 1 year without any right to an
extension) unless it is within 1 month redelivered to the Borrower’s full control; 

  

	(c)	any arrest, capture, seizure or detention of the Ship (including any hijacking or theft) unless it is within 1 month redelivered to the Borrower’s full control. 

“Total Loss Date” means: 
  

	(a)	in the case of an actual loss of the Ship, the date on which it occurred or, if that is unknown, the date when the Ship was last heard of; 

 

	(b)	in the case of a constructive, compromised, agreed or arranged total loss of the Ship, the earliest of: 

  

	(i)	the date on which a notice of abandonment is given to the insurers; and 

  

	(ii)	the date of any compromise, arrangement or agreement made by or on behalf of the Borrower with the Ship’s insurers in which the insurers agree to treat the Ship as a total loss; and 

 

	(c)	in the case of any other type of total loss, on the date (or the most likely date) on which it appears to the Agent acting reasonably and in consultation with the Borrower that the event constituting the total loss
occurred. 

 “Transaction Documents” means the Finance Documents and the Underlying Documents. 

“Transfer Certificate” means a certificate substantially in the form set out in Schedule 4 (Form of Transfer Certificate) or any other
form agreed between the Agent and the Borrower. 
 “Tripartite General Assignment” means an assignment of the Seven Seas Charter, the
Earnings, the Insurances and any Requisition Compensation, executed or to be executed by the Borrower, Seven Seas (as bareboat charterer) and, in the event that the Approved Manager is not a member of the Group and is named as a co-assured in the
Insurances, the Approved Manager in favour of the Security Trustee in the agreed form. 
 “Underlying Documents” means the Shipbuilding
Contract, any External Management Agreement, the Seven Seas Charter and any charter and associated guarantee in respect of which a notice of assignment is required to be served under the terms of the Tripartite General Assignment. 

“Unpaid Sum” means any sum due and payable but unpaid by an Obligor under the Finance Documents. 

“VAT” means: 
  

	(a)	any tax imposed in compliance with the Council Directive of 28 November 2006 on the common system of value added tax (EC Directive 2006/112); and 

 

	(b)	any other tax of a similar nature, whether imposed in a member state of the European Union in substitution for, or levied in addition to, such tax referred to in paragraph (a) above, or imposed elsewhere.

  
 19 

 1.2 Construction of certain terms 

In this Agreement: 
 “Agent”, the “SACE
Agent”, the “Joint Mandated Lead Arranger”, the “Security Trustee”, any “Creditor Party”, any “Secured Party”, any “Lender”, any “Obligor”
or any other “person”, shall be construed so as to include its successors in title, permitted assigns and permitted transferees; 

“asset” includes every kind of property, asset, interest or right, including any present, future or contingent right to any revenues or other
payment. 
 “company” includes any partnership, joint venture and unincorporated association. 

“consent” includes an authorisation, consent, approval, resolution, licence, exemption, filing, registration, notarisation and legalisation.

 “contingent liability” means a liability which is not certain to arise and/or the amount of which remains unascertained. 

“document” includes a deed; also a letter, fax or electronic mail. 

“expense” means any kind of cost, charge or expense (including all legal costs, charges and expenses) and any applicable Taxes including VAT.

 “including” and “in particular” (and other similar expressions) shall be construed as not limiting any general words or
expressions in connection with which they are used. 
 “indebtedness” includes any obligation (whether incurred as principal or as surety)
for the payment or repayment of money, whether present or future, actual or contingent; 
 “law” includes any order or decree, any form of
delegated legislation, any treaty or international convention and any regulation or resolution of the Council of the European Union, the European Commission, the United Nations or its Security Council. 

“legal or administrative action” means any legal proceeding or arbitration and any administrative or regulatory action or investigation. 

“liability” includes every kind of debt or liability (present or future, certain or contingent), whether incurred as principal or surety or
otherwise. 
 “months” shall be construed in accordance with Clause 1.4 (Meaning of “month”). 

“parent company” has the meaning given in the definition of “Subsidiary”. 

“person” includes any individual, firm, company, corporation, government, any state, political sub-division of a state and local or municipal
authority, agency of a state or any association, trust, joint venture, consortium or partnership; and any international organisation (whether or not having a separate legal personality). 

“proceedings” means, in relation to any enforcement provision of a Finance Document, proceedings of any kind, including an application for a
provisional or protective measure; 

  
 20 

 “regulation” includes any regulation, rule, official directive, request or guideline (whether or
not having the force of law) of any governmental, intergovernmental or supranational body, agency, department or regulatory, self-regulatory or other authority or organisation. 

1.3 Construction of Insurance Terms 

“approved” means, for the purposes of Clause 14 (Insurance Undertakings), approved in writing by the Agent. 

“excess risks” means the proportion of claims for general average, salvage and salvage charges not recoverable under the hull and machinery
policies in respect of the Ship in consequence of its insured value being less than the value at which the Ship is assessed for the purpose of such claims. 

“obligatory insurances” means all insurances effected, or which the Borrower is obliged to effect, under Clause 14 (Insurance
Undertakings) or any other provision of this Agreement or another Finance Document. 
 “policy” in relation to any insurance, includes
a slip, cover note, certificate of entry or other document evidencing the contract of insurance or its terms. 
 “protection and indemnity
risks” means the usual risks covered by a protection and indemnity association managed in London, including pollution risks and the proportion (if any) of any sums payable to any other person or persons in case of collision which are not
recoverable under the hull and machinery policies by reason of the incorporation in them of Clause 1 of the Institute Time Clauses (Hulls)(1/10/82) or Clause 8 of the Institute Time Clauses (Hulls) (1/11/1995) or the Institute Amended Running
Down clause (1/10/71) or any equivalent provision. 
 “war risks” includes the risk of mines and all risks excluded by Clause 23 of
the Institute Time Clauses (Hulls)(1/10/83) or clause 24 of the Institute Time Clauses (Hulls) (1/11/1995). 
 1.4 Meaning of “month” 

A period of one or more “months” ends on the day in the relevant calendar month numerically corresponding to the day of the calendar month on
which the period started (“the numerically corresponding day”), but: 
  

	(a)	on the Business Day following the numerically corresponding day if the numerically corresponding day is not a Business Day or, if there is no later Business Day in the same calendar month, on the Business Day preceding
the numerically corresponding day; or 

  

	(b)	on the last Business Day in the relevant calendar month, if the period started on the last Business Day in a calendar month or if the last calendar month of the period has no numerically corresponding day;

 and “month” and “monthly” shall be construed accordingly. 

1.5 General Interpretation 
 In this Agreement: 

 

	(c)	references in Clause 1.1 (Definitions) to a Finance Document or any other document being an “agreed form” are to the form agreed between the Agent (acting with the authorisation of each of the
Creditor Parties) and the Borrower with any modifications to that form which the Agent (with the authorisation of the Majority Lenders in the case of substantial modifications) approves or reasonably requires; 

  
 21 

	(d)	references to, or to a provision of, a Finance Document or any other document are references to it as amended or supplemented, whether before the date of this Agreement or otherwise; 

 

	(e)	references to, or to a provision of, any law include any amendment, extension, re-enactment or replacement, whether made before the date of this Agreement or otherwise; 

 

	(f)	any English legal term for any action, remedy, method of judicial proceeding, legal document, legal status, court, official or any legal concept or thing shall, in respect of a jurisdiction other than England, be deemed
to include that which most nearly approximates in that jurisdiction to the English legal term; 

  

	(g)	words denoting the singular number shall include the plural and vice versa; and 

  

	(h)	Clauses 1.1 (Definitions) to 1.5 (General Interpretation) apply unless the contrary intention appears. 

1.6 Headings 
 In interpreting a Finance Document or any
provision of a Finance Document, all clauses, sub-clauses and other headings in that and any other Finance Document shall be entirely disregarded. 
 1.7
Schedules 
 The schedules form an integral part of this Agreement. 

2 FACILITY 
 2.1 Amount of facility 

Subject to the other provisions of this Agreement, the Lenders agree to make available to the Borrower a loan not exceeding the Maximum Loan Amount intended to
be applied as follows: 
  

	(a)	in payment to the Builder of all or part of 80% of the Final Contract Price up to the Eligible Amount; 

  

	(b)	in reimbursement to the Borrower of the amount of the First Instalment of the SACE Premium paid by it to SACE on or before 30 days following the issuance of the SACE Insurance Policy; and 

 

	(c)	in payment to SACE of the amount of the Second Instalment of the SACE Premium payable by the Borrower to SACE on the Drawdown Date. 

2.2 Lenders’ participations in Loan 
 Subject to the
other provisions of this Agreement, each Lender shall participate in the Loan in the proportion which, as at the Drawdown Date, its Commitment bears to the Total Commitments. 

2.3 Purpose of Loan 
 The Borrower undertakes with each
Secured Party to use the Loan only to pay for: 
  

	(a)	goods and services of Italian origin incorporated in the design, construction or delivery of the Ship; 

  
 22 

	(b)	subject to the limits and conditions fixed by the Italian Authorities, goods and services incorporated in the design, construction or delivery of the Ship and originating from countries other than Italy where the
provision of such goods or services has been sub-contracted by the Builder and therefore remains the Builder’s responsibility under the Shipbuilding Contract; 

 

	(c)	reimbursement to the Borrower of the First Instalment of the SACE Premium paid by the Borrower direct to SACE 30 days following the issuance of the SACE Insurance Policy; and 

 

	(d)	the Second Instalment of the SACE Premium payable on the Drawdown Date. 

 2.4 Creditor Parties’ rights
and obligations 
  

	(a)	The obligations of each Creditor Party under the Finance Documents are several. Failure by a Creditor Party to perform its obligations under the Finance Documents does not affect the obligations of any other Party under
the Finance Documents. No Creditor Party is responsible for the obligations of any other Creditor Party under the Finance Documents. 

  

	(b)	The rights of each Creditor Party under or in connection with the Finance Documents are separate and independent rights and any debt arising under the Finance Documents to a Creditor Party from an Obligor shall be a
separate and independent debt. 

  

	(c)	A Creditor Party may not, except as otherwise stated in the Finance Documents, separately enforce its rights under the Finance Documents. 

 

	(d)	Notwithstanding any other provision of the Finance Documents and subject to the prior written consent of SACE, a Creditor Party may separately sue for any Unpaid Sum due to it without the consent of any other Creditor
Party or joining any other Creditor Party to the relevant proceedings (it being understood that a Creditor Party may file a claim noting the amounts due to it in the event insolvency proceedings are commenced against the Borrower by a third party.)

 2.5 Monitoring 
 No Creditor Party is
bound to monitor or verify the application of any amount borrowed pursuant to this Agreement. 
 2.6 Obligations of Lenders several 

The obligations of the Lenders under this Agreement are several; and a failure of a Lender to perform its obligations under this Agreement shall not result in:

  

	(a)	the obligations of the other Lenders being increased; nor 

  

	(b)	any Obligor or any other Lender being discharged (in whole or in part) from its obligations under any Finance Document; 

and in no circumstances shall a Lender have any responsibility for a failure of another Lender to perform its obligations under this Agreement or any other
Finance Document. 
 2.7 Independent Repayment Obligations 
  

	(a)	The Borrower’s obligations under this Agreement are separate from and are not in any way conditional upon the performance of the Shipbuilding Contract by the Builder or any other person and will not be affected or
discharged by any matter affecting the Contract or any other contract or other arrangement between the Builder and any other party to the Contract including, without limitation, the performance, non-performance, frustration or invalidity or the
destruction, non-completion, or non-functioning of any of the items to be supplied under the Contract (including those to be supplied by the Builder) or the liquidation or bankruptcy of the Builder. 

 

	(b)	The Borrower’s repayment obligations under this Agreement will not be affected in any way by reason of any claim which the Borrower may have or may consider that it has against the Builder or any other person under
the Contract. 

 3 CONDITIONS PRECEDENT 

3.1 General 
 The Borrower may only draw under the Loan
when the following conditions have been fulfilled to the satisfaction of the Agent and provided no Event of Default shall have occurred and remains unremedied or is likely to occur as a consequence of the drawing of the Loan: 

3.2 No later than the date of this Agreement 
 The Agent
shall have received no later than the date of this Agreement: 
  

	(a)	an opinion from legal counsel acceptable to the Secured Parties as to the laws of the state of Delaware in form and substance satisfactory to the Agent and SACE, together with the limited liability company documentation
of the Borrower supporting the opinion, including but without limitation the Certificate of Formation and Limited Liability Company Agreement as filed with the competent authorities and a certificate of a competent officer or manager of the Borrower
containing specimen signatures of the persons authorised to sign the documents on behalf of the Borrower, including, without limitation: 

  

	(i)	the Borrower has been duly formed and is validly existing as a limited liability company under the laws of the state of Delaware; 

  

	(ii)	this Agreement falls within the scope of the Borrower’s limited liability company purpose as defined by its Certificate of Formation and Limited Liability Company Agreement; 

 

	(iii)	the Borrower’s representatives were at the date of this Agreement fully empowered to sign this Agreement; 

  

	(iv)	either all administrative requirements applicable to the Borrower (whether in the state of Delaware or elsewhere), concerning the transfer of funds abroad and acquisitions of Dollars to meet its obligations hereunder
have been complied with, or that there are no such requirements; 

  

	(v)	no withholding tax or stamp duty implications arise by virtue of the Borrower entering into this Agreement; 

  

	(vi)	a judgment of an English Court in relation to the Agreement and any relevant Finance Documents will be recognised by and acknowledged by the Courts in the State of Delaware; and 

 

	(vii)	this Agreement constitutes the legal, valid and binding obligations of the Borrower enforceable in accordance with its terms, 

and containing such qualifications and assumptions as are standard for opinions of this type; 

 

	(b)	an opinion from legal counsel to the Creditor Parties as to English law confirming, without limitation, that (i) the obligations of the Borrower under this Agreement and (ii) that the obligations of each
Guarantor under the relevant Guarantee are legally valid and binding obligations enforceable by the relevant Creditor Parties; 

 Execution Copy 

 

	(c)	an opinion from legal counsel to SACE as to English law (to be solely addressed to the Italian Authorities) in form and substance satisfactory to SACE; 

 

	(d)	a Certified Copy of the executed Shipbuilding Contract; 

  

	(e)	a confirmation from EC3 Services Limited that it will act for the Borrower as agent for service of process in England in respect of this Agreement and any other Finance Document; 

 

	(f)	an opinion from legal counsel acceptable to the Secured Parties as to Panamanian law in form and substance satisfactory to the Agent and SACE, together with the corporate documentation of each Guarantor supporting the
opinion, including but without limitation the Articles of Incorporation and By-laws as filed with the competent authorities and a certificate of a competent officer of each Guarantor containing specimen signatures of the persons authorised to sign
the documents on behalf of the Guarantor including without limitation: 

  

	(i)	each Guarantor has been duly organised and is validly existing and in good standing as a Panamanian sociedad anonima or a sociedad de responsibilidad limitada with its domicile in the Republic of Panama
and each Guarantor’s Resident Agent being Arias Fabrega & Fabrega with address at Plaza 2000 Building, 16th Floor, 50th Street, Panama; 

  

	(ii)	each Guarantee falls within the scope of the relevant Guarantor’s corporate purpose as defined by its Articles of Incorporation and By-laws; 

 

	(iii)	each Guarantor’s representative was at the date of the Guarantee issued by it fully empowered to sign and duly execute that Guarantee; 

 

	(iv)	either all administrative requirements applicable to each Guarantor (whether in the Republic of Panama) concerning the transfer of funds abroad and acquisitions of Dollars to meet its obligations under the Guarantee
issued by it have been complied with, or that there are no such requirements; 

  

	(v)	each Guarantee is the legal, valid and binding obligations of the Guarantor which issued it enforceable in accordance with its terms; 

 

	(vi)	the Limited Liability Company Interests Security Deed falls within the scope of Seven Seas’ corporate purpose as defined by its Articles of Incorporation and By-laws; and 

 

	(vii)	the representative of Seven Seas was at the date of the Limited Liability Company Interests Security Deed fully empowered to sign the Limited Liability Company Interests Security Deed. 

 

	(viii)	a judgment of an English Court in relation to the Guarantees will be recognised by and acknowledged by the Courts of Panama; and 

  

	(ix)	none of the undertakings of either Guarantor contained in either Guarantee are contrary to public policy in the Republic of Panama, 

and containing such qualifications and assumptions as are standard for opinions of this type; 

 

	(g)	duly executed originals of the Guarantees and the Limited Liability Security Deed; and 

  

	(h)	confirmation from EC3 Services Limited that it will act for each Guarantor as agent for service of process in England in respect of the Guarantee issued by that Guarantor and any other Finance Document.

  
 25 

 Execution Copy 

 

 3.3 No later than ninety (90) days before the Intended Delivery Date 

The Agent shall have received no later than ninety (90) days before the Intended Delivery Date: 

 

	(a)	notification from the Borrower of its chosen Maritime Registry; 

  

	(b)	the SACE Insurance Policy documentation relating to the transaction contemplated by this Agreement issued on terms whereby the SACE Insurance Policy will enter into full force and effect upon fulfilment of the
conditions specified therein to be fulfilled on or before the Drawdown Date; 

  

	(c)	evidence that the Borrower has paid the First Instalment of the SACE Premium to SACE on or before 30 days following the issuance of the SACE Insurance Policy; and 

 

	(d)	notification of the Approved Manager. 

  

	3.4	No later than the date falling ninety (90) days before the Intended Delivery Date and on each subsequent date on which a Compliance Certificate is to be received by the Security Trustee pursuant to clause
11.3(e) of the Prestige Holdings Guarantee and clause 11.3(d) of the Seven Seas Guarantee a duly completed Compliance Certificate from each of Prestige Holdings and Seven Seas. 

3.5 No later than sixty (60) days before the Intended Delivery Date 
  

	(a)	The Agent shall have received from the Borrower no later than sixty (60) days before the Intended Delivery Date: 

  

	(i)	notification of the Intended Delivery Date; and 

  

	(ii)	notification, signed by a duly authorised signatory of the Borrower, specifying which of the Fixed Interest Rate or the Floating Interest Rate shall be applicable to the Loan until the date of payment of the final
repayment instalment of the Loan; and in absence of any such notification, the Borrower shall be deemed to have opted for the Floating Interest Rate; and 

  

	(iii)	a US tax opinion from legal counsel to the Creditor Parties in respect of the tax treatment of the entry by the US incorporated Borrower into this Agreement and the other Finance Documents substantially in the form
notified to the Borrower on or around the date of this Agreement and updated to reflect any changes in law; 

  

	(b)	The Agent (acting on the instructions of the Lenders) shall notify to the Borrower any documents required under the ISM Code and the ISPS Code which are to be provided at delivery pursuant to Clause 3.10(f) below.

 3.6 No later than fifteen (15) Business Days before the Intended Delivery Date 

The Agent shall have received no later than fifteen (15) Business Days before the Intended Delivery Date insurance documents in form and substance
satisfactory to the Lenders confirming that the Insurances have been effected and will be in full force and effect on the Delivery Date. 
 3.7 No later
than five (5) Business Days before the Intended Delivery Date 
 The Agent shall have received no later than five (5) Business Days before the
Intended Delivery Date: 
  

	(a)	the Drawdown Notice from the Borrower, signed by a duly authorised signatory of the Borrower, specifying the amount of the Loan to be drawn down; 

  
 26 

 Execution Copy 

 

	(b)	a Certified Copy of each of the Change Orders, of any amendments to the Shipbuilding Contract and of the power of attorney pursuant to which the authorised signatory of the Borrower signed the Drawdown Notice and a
specimen of his signature; 

  

	(c)	a final confirmation of the Intended Delivery Date signed by a duly authorised signatory of the Borrower, and counter-signed by a duly authorised signatory of the Builder. 

3.8 Examination of documents by the Agent 
 The Agent
shall ensure that an officer or employee or other person designated by it as its authorised representative is present at the Builder on the proposed Drawdown Date for the purpose of examining originals (or certified copies) of the SACE Required
Documents duly signed by the parties thereto and collecting copies thereof (which copies shall be certified as true copies by an authorised signatory of the Builder and/or the Borrower, as applicable). 

3.9 No later than the Delivery Date 
 The Agent shall have
received no later than the Delivery Date: 
  

	(a)	an opinion from legal counsel acceptable to the Secured Parties as to the laws of the state of Delaware in form and substance satisfactory to the Agent and SACE together with the limited liability company documentation
of the Borrower and a certificate of a competent officer or manager of the Borrower containing specimen signatures of the persons authorised to sign the documents on behalf of the Borrower, confirming that, without limitation: 

 

	(i)	the Mortgage, the Tripartite General Assignment, the Post-Delivery Assignment and the Seven Seas Charter fall within the scope of the Borrower’s limited liability company purpose as defined by its Certificate of
Formation and Limited Liability Company Agreement and are binding on it; and 

  

	(ii)	the Borrower’s representatives are fully empowered to sign the Protocol of Delivery and Acceptance, the Mortgage, the Tripartite General Assignment, the Post-Delivery Assignment and the Seven Seas Charter.

  

	(b)	evidence of payment to and receipt by the Builder of: 

  

	(i)	the [*] pre-delivery instalments of the Final Contract Price; and 

  

	(ii)	any other part of the Final Contract Price as at the Delivery Date not being financed hereunder; 

  

	(c)	evidence of payment of all amounts which are due and payable hereunder by the Borrower on or prior to the Delivery Date; 

  

	(d)	a certificate from the Borrower, signed by an authorised representative of the Borrower, confirming that the representations and warranties contained in Clause 11 (Representations and Warranties) are true and
correct as of the Delivery Date in consideration of the facts and circumstances existing as of the Delivery Date; 

  

	(e)	an original of the Interest Make-up Agreement relative to the Loan and in full force and effect; 

  

	(f)	a duly executed original of the SACE Reimbursement Agreement; 

  
 27 

 Execution Copy 

 

	(g)	an original of the SACE Insurance Policy; 

  

	(h)	an original or a certified copy of each of the SACE Required Documents and SACE and the Agent shall be satisfied that the SACE Required Documents on their face appear properly completed and comply with the requirements
of this Agreement and the requirements of the SACE Insurance Policy; and 

 provided always that the obligations of the Lenders to make the
Loan available on the Delivery Date are subject to the Lenders remaining satisfied that each of the SACE Insurance Policy and the Interest Make-up Agreement will cover the Loan following the advance of the Loan, payment of the Second Instalment of
the SACE Premium and delivery to the Agent of the documents listed in Schedule 3. 
 3.10 At Delivery 

Immediately prior to the delivery of the Ship by the Builder to the Borrower, the Agent shall have received: 

 

	(a)	evidence that immediately following delivery: 

  

	(i)	the Ship will be registered in the name of the Borrower in the Maritime Registry; 

  

	(ii)	title to the Ship will be held by the Borrower free of all Security Interests other than any maritime lien in respect of crew’s wages and trade debts arising out of equipment, consumable and other stores placed on
board the Ship prior to or concurrently with delivery, none of which is overdue; 

  

	(iii)	the Mortgage will be duly registered in the Maritime Registry and constitutes a first priority security interest over the Ship and that all taxes and fees payable to the Maritime Registry in respect of the Ship have
been paid in full; and 

  

	(iv)	the opinions mentioned in Clauses 3.11(b), (c) and (d) and the documents mentioned in Clause 3.11(e) will be received by the Agent; 

 

	(b)	a Certified Copy of a classification certificate (or interim classification certificate) showing the Ship to be classed in accordance with Clause 11.3(c). 

 

	(c)	duly executed originals of the Tripartite General Assignment, any Approved Manager’s Undertaking and the Post-Delivery Assignment together with relevant notices of assignment and the acknowledgement of the notice
of assignment to be issued pursuant to the Tripartite General Assignment and the Post-Delivery Assignment; 

  

	(d)	a duly executed original of the Limited Liability Company Interests Security Deed (and of each document required to be delivered under the Limited Liability Company Interests Security Deed); 

 

	(e)	a Certified Copy of any executed External Management Agreement, the Seven Seas Charter and any time charterparty in respect of the Ship; 

 

	(f)	a Certified Copy of any current certificate of financial responsibility in respect of the Ship issued under OPA, a valid Safety Management Certificate (or interim Safety Management Certificate) issued to the Ship in
respect of its management by the Approved Manager pursuant to the ISM Code, a valid Document of Compliance (or interim Document of Compliance) issued to the Approved Manager in respect of ships of the same type as the Ship pursuant to the ISM Code,
a valid International Ship Security Certificate issued to the Ship in accordance with the ISPS Code and a valid IAPPC issued to the Ship in accordance with Annex VI and, if entered into, any carrier initiative agreement with the United States’
Customs and Border Protection under the Customs-Trade Partnership Against Terrorism (C-TPAT) programme along with any other documents required under the ISM Code and the ISPS Code and notified to the Borrower in accordance with Clause 3.5(b) above;

  
 28 

 Execution Copy 

 

	(g)	a Certified Copy of the power of attorney pursuant to which the authorised signatory(ies) of the Borrower signed the documents referred to in this Clause 3.10 (At Delivery) and to which the Borrower is a party
and a specimen of his or their signature(s); 

  

	(h)	a confirmation from EC3 Services Limited (or any replacement process agent satisfactory to the Agent acting reasonably) that it will act for each of the relevant Obligors as agent for service of process in England in
respect of the deed of covenants constituting part of the Mortgage (if applicable), the Tripartite General Assignment and the Post-Delivery Assignment. 

  

	3.11	Immediately following the delivery of the Ship by the Builder to the Borrower, the Agent shall receive: 

  

	(a)	a duly executed original of the Mortgage; 

  

	(b)	an opinion from legal counsel acceptable to the Secured Parties as to the law of the Maritime Registry in form and substance satisfactory to the Agent and SACE confirming: 

 

	(i)	the valid registration of the Ship in the Maritime Registry; and 

  

	(ii)	the Mortgage over the Ship has been validly registered in the Maritime Registry; 

  

	(c)	an opinion from legal counsel to the Agent as to English law confirming, without limitation, that the obligations of the Borrower under the deed of covenants constituting part of the Mortgage (if applicable), the
Tripartite General Assignment and the Post-Delivery Assignment are legally valid and binding obligations enforceable by the relevant Creditor Parties in the English courts; 

 

	(d)	an opinion from legal counsel to SACE in relation to, inter alia, the English law Finance Documents to be signed on the Delivery Date (to be addressed solely to SACE) in form and substance satisfactory to SACE;

  

	(e)	the documents listed in Schedule 3 (Documents to be produced by the Builder to the Agent on Delivery). 

3.12 Waiver of conditions precedent 
 If the Majority
Lenders, at their discretion, subject to the prior written consent of SACE, permit the Loan to be borrowed before any of the conditions precedent referred to in Clause 3 (Conditions Precedent) has been satisfied, the Borrower shall ensure
that condition is satisfied within five (5) Business Days after the date (as specified in the relevant part of Clause 3 (Conditions Precedent)) or such later date as the Agent, acting with the authorisation of the Majority Lenders, may
agree in writing with the Borrower. 
 3.13 Changes to SACE requirements 
  

	(a)	If SACE notifies the Agent in writing of a change to the requirements of the SACE Insurance Policy with the effect that, in the opinion of the Agent, certain documents which the Borrower is or may be required to provide
for the purpose of drawing the Loan under this Agreement are no longer necessary to ensure that: 

  

	(i)	such SACE Insurance Policy will apply to the Loan made or to be made under this Agreement; and 

  

	(ii)	any claim which may be made in respect of the Loan under such SACE Insurance Policy will be valid and continue to be issued by SACE, 

  
 29 

 Execution Copy 

 

 then the Agent shall promptly notify the Borrower of any changes the Agent considers appropriate to be made
to this Agreement to reflect such a change in SACE’s requirements. 
  

	(b)	If the Agent notifies the Borrower of any proposed changes to this Agreement under paragraph (i) above, and provided that: 

  

	(i)	all the Lenders and the Borrower agree with such changes; and 

  

	(ii)	the Borrower indemnifies and holds harmless the Agent and the Lenders for any reasonable costs that it may incur arising from or in connection with any such amendments (including legal fees), 

then such changes will be made to this Agreement in accordance with the terms hereof. 

 

	(c)	If, in the opinion of the Lenders, there are any provisions of this Agreement that contradict or conflict with any provision of the SACE Insurance Policy to an extent that the same may have the effect of rendering all
or any part of the SACE Insurance Policy void, voidable or otherwise not in full force and effect, this Agreement will be amended to the extent agreed in writing between the Borrower and the Agent (acting on the instructions of the Majority Lenders)
to ensure compliance with the terms of the SACE Insurance Policy. 

 4 DRAWDOWN 

4.1 Borrower’s irrevocable payment instructions 
 The
Lenders shall not be obliged to fulfil their obligation to make the Loan available other than (i) by paying the Builder all or part of 80% of the Final Contract Price up to the Eligible Amount on behalf of and in the name of the Borrower,
(ii) by reimbursing the Borrower for the First Instalment of the SACE Premium which was paid by the Borrower to SACE on or before 30 days following the issuance of the SACE Insurance Policy and (iii) by payment to SACE of the Second
Instalment of the SACE Premium payable on the Delivery Date. For the avoidance of doubt, the amount of the Loan shall not exceed the Maximum Loan Amount. 

The Borrower hereby instructs the Lenders in accordance with this Clause 4.1 (Borrower’s irrevocable payment instructions): 

 

	(a)	to pay to the Builder all or part of 80% of the Final Contract Price up to the Eligible Amount. 

  

	(b)	to reimburse the Borrower the amount of the First Instalment of the SACE Premium already paid by the Borrower to SACE on or before 30 days following the issuance of the SACE Insurance Policy; and 

 

	(c)	to pay to the Agent on behalf of the Lenders for onward payment to SACE (such payment to SACE to be made for value on the Drawdown Date), by drawing under the Loan, the amount of the Second Instalment of the related
SACE Premium. 

 Payment to the Builder of the amount drawn under Clause 4.1(a) above shall be made on the Delivery Date of the Ship during
usual banking hours in Italy to the Builder’s account as specified by the Builder in accordance with the Shipbuilding Contract after receipt and verification by the Agent of the documents provided under Schedule 3 (Documents to be produced
by the Builder to the Agent on Delivery). 
 Save as contemplated in Clause 4.3 (Modification of payment terms) below, the payment instruction
contained in this Clause 4.1 (Borrower’s irrevocable payment instructions) is irrevocable. 

  
 30 

 4.2 Conversion Rate for Loan 

The Dollar amount to be drawn down under Clause 4.1(a) shall be calculated by the Agent on the Conversion Rate Fixing Date in accordance with the definitions
of “Eligible Amount” and “Conversion Rate” in Clause 1.1 (Definitions). 
 4.3 Modification of payment terms 

The Borrower expressly acknowledges that the payment terms set out in this Clause may only be modified with the agreement of the Italian Authorities, Agent,
the Security Trustee, the Lenders and the Borrower in the case of Clause 4.1(a) and with the agreement of the Italian Authorities, Agent, the Lenders and the Borrower in the case of Clause 4.1(b) and 4.1(c); Provided that it is the intention
of the Borrower, the Lenders, the Security Trustee and the Agent that prior to the Conversion Rate Fixing Date agreement shall be reached with those financial institutions with whom the Borrower has entered into the FOREX Contracts (the
“Counterparties”) in order that the Euro payments due from the Counterparties under the FOREX Contracts shall be paid to the Agent for holding in escrow and to be released by the Agent simultaneously with (i) the payment in
full to the Builder of the balance of the Final Contract Price denominated in Euro at the time of delivery of the Ship and (ii) the payment to the Counterparties of the Dollars due to them under the relevant FOREX Contracts out of the Dollar
amount available under Clause 4.1(a), subject only to delivery of the Ship by the Builder to the Borrower taking place as evidenced by the execution and delivery of the Protocol of Delivery and Acceptance and to the Borrower having deposited with
the Agent before delivery, if and to the extent required, any Dollar and/or Euro amounts as may be needed to ensure the payment in full of both the balance of the Final Contract Price in Euro and the Dollars owed to the Counterparties under all the
relevant FOREX Contracts. 
 4.4 Availability and conditions 
  

	(a)	Drawing may not be made under this Agreement (and the Loan shall not be available) after the earlier of the Delivery Date and the expiry of the Availability Period. 

 

	(b)	There will be only one Drawing under this Agreement. 

  

	(c)	The Drawing cannot exceed the Maximum Loan Amount. 

 4.5 Notification to Lenders of receipt of a Drawdown
Notice 
 The Agent shall promptly notify the Lenders that it has received a Drawdown Notice and shall inform each Lender of: 

 

	(a)	the amount of the Loan and the Drawdown Date; 

  

	(b)	the amount of that Lender’s participation in the Loan; and 

  

	(c)	the duration of the first Interest Period. 

 4.6 Lenders to make available Contributions 

Subject to the provisions of this Agreement, each Lender shall, on and with value on the Drawdown Date, make available to the Agent the amount due from that
Lender under Clause 2.2 (Lenders’ participations in Loan). 
 4.7 Disbursement of Loan 

Subject to the provisions of this Agreement, the Agent shall on the Drawdown Date pay the amounts which the Agent receives from the Lenders under Clause 4.6
(Lenders to make available Contributions) in the like funds as the Agent received the payments from the Lenders: 
  

	(a)	in the case of the amount referred to in Clause 4.1(a), to the account of the Builder which the Borrower specifies in the Drawdown Notice; and 

	(b)	in the case of the amount referred to in Clause 4.1(b) to the account of the Borrower which the Borrower shall specify; and 

  

	(c)	in the case of the amount referred to in Clause 4.1(c) to the account of SACE which the SACE Agent shall specify. 

4.8 Disbursement of Loan to third party 
 The payment by
the Agent under Clause 4.7 (Disbursement of Loan) shall constitute the making of the Loan and the Borrower shall at that time become indebted, as principal and direct obligor, to each Lender in an amount equal to that Lender’s
Contribution. 
 5 REPAYMENT 
 5.1 Number of
repayment instalments 
 The Borrower shall repay the Loan by twenty-four (24) consecutive six-monthly
instalments. 
 5.2 Repayment Dates 
 The first
instalment shall be repaid on the date falling six (6) months after the Delivery Date and the last instalment on the date falling one hundred and forty four (144) months after the Delivery Date, each date of payment of an instalment being
a “Repayment Date”. 
 5.3 Amount of repayment instalments 

Each of the twenty-four (24) consecutive six-monthly repayment instalments of the Loan shall be of an equal amount. 

5.4 Final Repayment Date 
 On the final Repayment Date,
the Borrower shall additionally pay to the Agent for the account of the Creditor Parties all other sums then accrued or owing under any Finance Document. 

6 INTEREST 
 6.1 Fixed Interest Rate 

If the Borrower has specified a Fixed Interest Rate pursuant to Clause 3.5(a)(ii), the Loan shall bear interest at the Fixed Interest Rate. Such interest shall
accrue on the actual number of days elapsed based upon a 360 day year and shall be paid on each Repayment Date. 
 6.2 Floating Interest Rate 

If: 
  

	(a)	the Borrower has specified a Floating Interest Rate pursuant to Clause 3.5(a)(ii); or 

 Execution Copy 

 

	(b)	the Borrower has specified a Fixed Interest Rate pursuant to Clause 3.5(a)(ii) but thereafter for any reason whatsoever the Interest Make-up Agreement is suspended or otherwise ceases to be in effect; or

  

	(c)	SIMEST has requested a change of currency pursuant to the Interest Make-Up Agreement and such change of currency is not agreed by the Borrower or Lenders in accordance with Clause 6.15 (6.15 Change of currency);
or 

  

	(d)	SIMEST has failed to make a net payment of interest to the Lenders pursuant to the Interest Make-Up Agreement, 

the rate of interest on the Loan in respect of any Interest Period shall be the Floating Interest Rate applicable for that Interest Period and the following
provisions of this Clause 6 (Interest) shall apply (in the case of the circumstances referred to in paragraph (b) above, with effect from the date on which the Interest Make-up Agreement ceases to be in effect, with such consequential
amendments as shall be necessary to give effect to the switch from a Fixed Interest Rate to a Floating Interest Rate). 
 6.3 Payment of Floating
Interest Rate 
 Subject to the provisions of this Agreement, interest on the Loan in respect of each Interest Period shall accrue on the actual number
of days elapsed based upon a 360 day year and shall be paid by the Borrower on the last day of that Interest Period. 
 6.4 Notification of Interest
Periods and Floating Interest Rate 
 The Agent shall notify the Borrower and each Lender of each Floating Interest Rate and the duration of each
Interest Period as soon as reasonably practicable after each is determined and no later than the Quotation Date. 
 6.5 Market disruption 

The following provisions of this Clause 6 (Interest) apply if: 
  

	(a)	No rate is quoted on “Reuters Page LIBOR 01 or LIBOR 02” (or any other page replacing it) and the Lenders do not, before 1.00 p.m. (London time) on the Quotation Date for an Interest Period, provide quotations
to the Agent in order to fix LIBOR; or 

  

	(b)	at least 1 Business Day before the start of an Interest Period, Lenders having Contributions together amounting to more than [*]% of the Loan (or, if the Loan has not been made, Commitments amounting to more than [*]%
of the Total Commitments) notify the Agent that LIBOR fixed by the Agent would not accurately reflect the cost to those Lenders of funding their respective Contributions (or any part of them) during the Interest Period in the London Interbank Market
at or about 11.00 a.m. (London time) on the Quotation Date for the Interest Period; or 

  

	(c)	at least 1 Business Day before the start of an Interest Period, the Agent is notified by a Lender (the “Affected Lender”) that for any reason it is unable to obtain Dollars in the London Interbank
Market in order to fund its Contribution (or any part of it) during the Interest Period. 

 6.6 Notification of market disruption 

The Agent shall promptly notify the Borrower and each of the Lenders stating the circumstances falling within Clause 6.5 (Market disruption) which have
caused its notice to be given. 

  
 33 

 Execution Copy 

 

 6.7 Suspension of drawdown 

If the Agent’s notice under Clause 6.5 (6.5 Market disruption) is served before the Loan is made: 

 

	(a)	in a case falling within Clauses 6.5(a) or 6.5(b), the Lenders’ obligations to make the Loan; 

  

	(b)	in a case falling within Clause 6.5(c), the Affected Lender’s obligation to participate in the Loan; 

shall be suspended while the circumstances referred to in the Agent’s notice continue. 

6.8 Negotiation of alternative rate of interest 
 If the
Agent’s notice under Clause 6.6 (6.6 Notification of market disruption) is served after the Loan is made, the Borrower, the Agent and the Lenders or (as the case may be) the Affected Lender shall use reasonable endeavours to agree, in
consultation with SACE, within the 30 days after the date on which the Agent serves its notice under Clause 6.6 (6.6 Notification of market disruption) (the “Negotiation Period”), an alternative interest rate or (as the case
may be) an alternative basis for the Lenders or (as the case may be) the Affected Lender to fund or continue to fund their or its Contribution during the Interest Period concerned. 

6.9 Application of agreed alternative rate of interest 

Any alternative interest rate or an alternative basis which is agreed during the Negotiation Period shall take effect in accordance with the terms agreed. 

6.10 Alternative rate of interest in absence of agreement 

If an alternative interest rate or alternative basis is not agreed within the Negotiation Period, and the relevant circumstances are continuing at the end of
the Negotiation Period, then the Agent shall, with the agreement of each Lender or (as the case may be) the Affected Lender (and in consultation with SACE), set an interest period and interest rate representing the cost of funding of the Lenders or
(as the case may be) the Affected Lender in Dollars or in any available currency of their or its Contribution plus the Margin; and the procedure provided for by this Clause 6.10 (Alternative rate of interest in absence of agreement) shall be
repeated if the relevant circumstances are continuing at the end of the interest period so set by the Agent. 
 6.11 Notice of prepayment 

If the Borrower does not agree with an interest rate set by the Agent under Clause 6.10 (6.10 Alternative rate of interest in absence of agreement), the
Borrower may give the Agent not less than 15 Business Days’, or, if the Fixed Interest Rate has been selected pursuant to Clause 3.5(a)(ii), 30 days, notice of its intention to prepay at the end of the interest period set by the Agent. 

6.12 Prepayment; termination of Commitments 
 A notice
under Clause 6.11 (Notice of prepayment) shall be irrevocable; the Agent shall promptly notify the Lenders or (as the case may require) the Affected Lender and, if the Fixed Interest Rate has been selected by the Borrower, SIMEST of the
Borrower’s notice of intended prepayment; and: 
  

	(a)	on the date on which the Agent serves that notice, the Total Commitments or (as the case may require) the Commitment of the Affected Lender shall be cancelled; and 

  
 34 

 Execution Copy 

 

	(b)	on the last Business Day of the interest period set by the Agent, the Borrower shall prepay (without premium or penalty subject to the provisions of Clause 20.2 (Breakage costs)) the Loan or, as the case may be,
the Affected Lender’s Contribution, together with accrued interest thereon at the applicable rate (being either the Floating Interest Rate or the Fixed Interest Rate as specified by the Borrower pursuant to Clause 3.5(a)(ii). 

6.13 Application of prepayment 
 The provisions of Clause
16 (16 Cancellation, ) shall apply in relation to the prepayment. 
 6.14 Certain Circumstances 

Notwithstanding anything to the contrary in this Agreement: 
  

	(a)	in the event of any circumstances falling within Clause 6.5 which might affect the advance of the Loan on the Drawdown Date (the “Relevant Circumstances”): 

 

	(i)	occurring and being continuing on the date falling ninety (90) days before the Intended Delivery Date (the “Relevant Date”), each Lender will notify the Borrower (through the Agent) of the Relevant
Circumstances on the Relevant Date or, if the Relevant Date is not a Business Day, on the next following Business Day; and 

  

	(ii)	occurring after the Relevant Date, each Lender will notify the Borrower (through the Agent) immediately each Lender become aware of the Relevant Circumstances; 

 

	(b)	in the event of any Relevant Circumstances falling within Clauses 6.5(a) or (b) (the “Pricing-Related Relevant Circumstances”) occurring before the Loan is made available and notwithstanding the
provisions of Clause 6.7, each Lender will fund its respective Contributions by reference to the agreed alternative rate of interest in accordance with Clauses 6.8, 6.9 and 6.10 as if the provisions of such Clauses applied not only in the event that
the Pricing-Related Relevant Circumstances have been notified by the Agent to the Borrower after the making of the Loan but also before the making of the Loan. 

  

	(c)	in the event of any Relevant Circumstances falling within 6.5(c) (the “Availability-Related Relevant Circumstances”) occurring before the Loan is made and notwithstanding the provisions of Clause 6.7 of
the Loan Agreement, each Lender will enter into good faith discussions with the Borrower for a period not exceeding 10 Business Days in order to discuss a basis on which the Lenders could be able to fund their respective Contributions in Dollars
(or, if unavailable in Dollars, then in any available currency). Such discussions shall be without obligation on the Lenders provided that during such discussion period, such circumstances continue. 

6.15 Change of currency 
  

	(a)	In the event that the Agent notifies the Borrower that SIMEST has requested a change in the currency of the Loan in accordance with clause 6.3 of the Interest Make-Up Agreement, the Borrower and the Lenders shall,
without obligation, consider such request for a change of currency acting reasonably for a period of not exceeding 10 Business Days. Following such discussions the Agent shall report the decision of the Borrower and the Lenders to SIMEST, providing
their reason for any negative decision. 

  

	(b)	In the event that a change of currency is agreed the Parties agree to negotiate in good faith the necessary changes to the Loan Agreement and the Finance Documents in order to document the change in currency.

  

	(c)	In the event that a change in currency is not acceptable to the Lenders or the Borrower, the provision of Clause 6.2(c) shall apply. 

  
 35 

 Execution Copy 

 

 7 INTEREST PERIODS 

7.1 Commencement of Interest Periods 
 The first Interest
Period shall commence on the Drawdown Date and each subsequent Interest Period shall commence on the expiry of the preceding Interest Period. 
 7.2
Duration of Interest Periods 
 Each Interest Period shall be 6 months and shall end on the next succeeding Repayment Date. 

8 SACE PREMIUM AND ITALIAN AUTHORITIES 
 8.1 SACE
Premium 
 The estimated SACE Premium is due and payable in two instalments as follows: 

 

	(a)	the first instalment of the SACE Premium (being an amount of US$[*]) (the “First Instalment”) shall be paid by the Borrower to SACE (provided the Borrower and the Lenders have been notified by the SACE
Agent that the SACE Insurance Policy has been issued) within 30 days of the issuance of the SACE Insurance Policy documentation in accordance with and as required by Clause 3.3(b) of this Agreement; and 

 

	(b)	the second instalment of the SACE Premium shall be such amount in Dollars as is calculated by SACE as being (i) [*]% of the Loan actually advanced on the Drawdown Date LESS (ii) the amount of the First
Instalment (the “Second Instalment”) and shall be payable on or prior to the Drawdown Date. 

 8.2 Reimbursement by the
Borrower of the SACE Premium 
 The Borrower irrevocably agrees to pay the First Instalment, and to instruct the Lenders to pay the Second Instalment on
behalf of the Borrower, as follows: 
  

	(a)	The Borrower has requested and the Lenders have agreed to reimburse the payment of [*]% of the First Instalment to the Borrower on the Drawdown Date, it being agreed that such First Instalment shall be paid to SACE by
the Borrower upon notification by the Agent to the Borrower (i) of the issue of the SACE Insurance Policy documentation in the form required by Clause 3.3(b) of this Agreement, and (ii) of the amount of the First Instalment.

  

	(b)	The Borrower has requested and the Lenders have agreed to finance the payment of [*]% of the Second Instalment on the Drawdown Date in accordance with Clause 2.1(c) of this Agreement. 

Consequently, the Borrower hereby irrevocably instructs the Agent on behalf of the Lenders to pay the Second Instalment to SACE on the Drawdown Date in
accordance with Clause 2.1(c) of this Agreement and to reimburse the Borrower by the Borrower drawing under the Loan the amount of the First Instalment in accordance with Clause 2.1(b) of this Agreement. 

The First Instalment and Second Instalment each financed by the Loan will be repayable in any event by the Borrower to the Lenders in the manner specified in
Clause 5 (Repayment) and under any and all circumstances including but without limitation in the event of prepayment or acceleration of the Loan. 

8.3 Italian Authorities 
  

	(a)	 The Borrower acknowledges and agrees that the Agent and the Lenders are entitled to provide the Italian Authorities with any information they may have
relative to the Loan and 

  
 36 

 Execution Copy 

 

	 	
the business of the Group, to allow the Italian Authorities to inspect all their records relating to this Agreement and the other Transaction Documents and to furnish them with copies thereof.
Any such information relative to the Loan may also be given by any Italian Authorities to international institutions charged with collecting statistical data. 

  

	(b)	The Borrower acknowledges that, in the making of any decision or determination or the exercise of any discretion or the taking or refraining to take any action under this Agreement or any of the other Finance Documents,
the Agent and the Lenders shall be deemed to have acted reasonably if they have acted on the instructions of either of the Italian Authorities. 

  

	(c)	Each Party further undertakes not to act in a manner which is inconsistent with the terms of the SACE Insurance Policy and the Interest Make Up Agreement. 

8.4 Refund 
  

	(a)	Provided that no Event of Default has occurred and is then continuing and no loss has occurred under the SACE Insurance Policy, the Borrower shall be entitled to a refund of the First Instalment of the SACE Premium in
accordance with the terms of the SACE Insurance Policy exclusively in the event that no disbursements have been made under this Agreement and, as a result thereof, the SACE Insurance Policy has been definitely terminated by mutual consent between
the parties thereto. 

  

	(b)	Any refund of the SACE Premium, whether in whole or in part, must be expressly requested from SACE by the Borrower in writing. Under the terms of the SACE Insurance Policy, a fixed amount of [*]% shall be withheld from
the amount of the SACE Premium to be refunded. Such withholding, charged as a lump sum to cover administration and management costs for the SACE Insurance Policy, may not, in any event, amount to less than the equivalent of €[*], calculated at
the exchange rate as at the date of the refund request. 

  

	(c)	Except as set out in paragraph (a) and (b) above, no part of the SACE Premium is refundable to any Obligor. 

  

	(d)	In no event shall the SACE Agent be liable for any refund of the SACE Premium to be made by SACE. 

 9 FEES

 9.1 Fees 
 The following fees shall be paid to the
Agent by the Borrower as required hereunder: 
  

	(a)	for the benefit of the Lenders, an arrangement fee in Euros, computed at the rate of [*]% flat on EUR 299,866,962.31 being the Maximum Loan Amount converted in to Euros at the Base Rate and payable on the date of this
Agreement; 

  

	(b)	for the benefit of the Lenders, a commitment fee in Dollars for the period from the date of this Agreement to the Delivery Date of the Ship, or the date of receipt by the Agent of the written cancellation notice sent by
the Borrower as described in Clause 15.1 (Security Shortfall), whichever is the earliest, computed at the rate of [*]% per annum and calculated on the undrawn amount of the Maximum Loan Amount and payable in arrears on the date falling six
(6) months after the date of this Agreement and on each date falling at the end of each following consecutive six (6) month period, with the exception of the commitment fee due in respect of the last period, which shall be paid on the
Drawdown Date, or the date of receipt by the Agent of the written cancellation notice sent by the Borrower as described in Clause 16.1 (Cancellation), whichever is the earliest, such commitment fee to be calculated on the actual number of
days elapsed divided by three hundred and sixty (360). For the purpose of the computation of the periodical commitment fee payable to the Lenders, the Maximum Loan Amount is assumed to be $440,321,648.78. 

  
 37 

 Execution Copy 

 

	(c)	for the Agent, an agency fee of $[*] payable on the date of this Agreement and on or before each anniversary date thereof until total repayment of the Loan unless the Total Commitments are terminated pursuant to Clause
16.1 (Cancellation). 

  

	(d)	for the SACE Agent a structuring fee in the amount and payable at the time separately agreed in writing between the SACE Agent and the Borrower; 

10 TAXES, INCREASED COSTS, COSTS AND RELATED CHARGES 

10.1 Definitions 
  

	(a)	In this Agreement: 

 “Protected Party” means a Secured Party which is or will be subject to
any liability, or required to make any payment, for or on account of Tax in relation to a sum received or receivable (or any sum deemed for the purposes of Tax to be received or receivable) under a Finance Document; 

“Tax Credit” means a credit against, relief or remission for, or repayment of any Tax. 

“Tax Deduction” means a deduction or withholding for or on account of Tax from a payment under a Finance Document other than a FATCA
Deduction. 
 “Tax Payment” means either the increase in a payment made by an Obligor to a Secured Party under Clause 10.2 (Tax
gross-up) or a payment under Clause 10.3 (Tax indemnity). 
  

	(b)	Unless a contrary indication appears, in this Clause 10 (Taxes, Increased Costs, Costs and Related Charges) reference to “determines” or “determined” means a determination made
in the absolute discretion of the person making the determination. 

 10.2 Tax gross-up 

 

	(a)	Each Obligor shall make all payments to be made by it under the Finance Documents without any Tax Deduction, unless a Tax Deduction is required by law. 

 

	(b)	The Borrower shall promptly upon becoming aware that an Obligor must make a Tax Deduction (or that there is any change in the rate or the basis of a Tax Deduction) notify the Agent accordingly. Similarly, a Lender shall
notify the Agent on becoming so aware in respect of a payment payable to that Lender. If the Agent receives such notification from a Lender it shall notify the Borrower and that Obligor. 

 

	(c)	If a Tax Deduction is required by law to be made by an Obligor, the amount of the payment due from that Obligor shall be increased to an amount which (after making any Tax Deduction) leaves an amount equal to the
payment which would have been due if no Tax Deduction had been required. 

  

	(d)	A payment shall not be increased under paragraph (c) above if on the date on which the payment falls due the Obligor making the payment is able to demonstrate that the payment could have been made to the Lender
without the Tax Deduction had that Lender (having been given notice of the documentation requested under Clause 10.7 at least 30 Business Days prior to such payment date) complied with its obligations under Clause 10.7 (Lender Status).

  

	(e)	If an Obligor is required to make a Tax Deduction, that Obligor shall make that Tax Deduction and any payment required in connection with that Tax Deduction within the time allowed and in the minimum amount required by
law. 

  

	(f)	 Within thirty days of making either a Tax Deduction or any payment required in connection with that Tax Deduction, the Obligor making that Tax
Deduction shall deliver to the Agent for 

  
 38 

 Execution Copy 

 

	 	
the Secured Party entitled to the payment evidence reasonably satisfactory to that Secured Party that the Tax Deduction has been made or (as applicable) any appropriate payment paid to the
relevant taxing authority. 

 10.3 Tax indemnity 
  

	(a)	The Borrower shall (within three Business Days of demand by the Agent) pay to a Protected Party an amount equal to the loss, liability or cost which that Protected Party determines will be or has been (directly or
indirectly) suffered for or on account of Tax by that Protected Party in respect of a Finance Document. 

  

	(b)	Paragraph (a) above shall not apply: 

  

	(i)	with respect to any Tax assessed on a Secured Party: 

  

	(A)	under the law of the jurisdiction in which that Secured Party is incorporated or, if different, the jurisdiction (or jurisdictions) in which that Creditor Party is treated as resident for tax purposes; or

  

	(B)	under the law of the jurisdiction in which that Lender’s Facility Office is located in respect of amounts received or receivable in that jurisdiction, 

if that Tax is imposed on or calculated by reference to the net income received or receivable (but not any sum deemed to be received or receivable) by that
Secured Party; or 
  

	(ii)	to the extent a loss, liability or cost is compensated for by an increased payment under Clause 10.2 (Tax gross-up) or would have been compensated for by an increased payment under Clause 10.2 (Tax
gross-up) but was not so compensated solely because an exclusion in paragraph (d) of Clause 10.2 (Tax gross-up) applied, or relates to a FATCA Deduction required to be made by a Party; or 

 

	(iii)	with respect to the Taxes in the nature of a branch profits tax imposed by Section 884(a) of the Code that is imposed by any jurisdiction described in paragraph (b)(i)(B) above. 

 

	(c)	A Protected Party making, or intending to make a claim under paragraph (a) above shall promptly notify the Agent of the event which will give, or has given, rise to the claim, following which the Agent shall notify
the Borrower. 

  

	(d)	A Protected Party shall, on receiving a payment from an Obligor under this Clause 10.3 (Tax indemnity), notify the Agent. 

10.4 Tax Credit 
 If an Obligor makes a Tax Payment and
the relevant Creditor Party determines that: 
  

	(a)	a Tax Credit is attributable to an increased payment of which that Tax Payment forms part, to that Tax Payment or to a Tax Deduction in consequence of which that Tax Payment was required; and 

 

	(b)	that Creditor Party has obtained, retained and utilised that Tax Credit, 

  
 39 

 Execution Copy 

 

 the Creditor Party shall pay an amount to the Obligor which that Creditor Party determines will leave it
(after that payment) in the same after-Tax position as it would have been in had the Tax Payment not been required to be made by the Obligor. 
 10.5
Stamp taxes 
 The Borrower shall pay and, within three Business Days of demand, indemnify each Secured Party against any cost, loss or liability that
Secured Party incurs in relation to all stamp duty, registration and other similar Taxes payable in respect of any Finance Document. 
 10.6 VAT 

 

	(a)	All amounts expressed to be payable under a Finance Document by any Party to a Secured Party which (in whole or in part) constitute the consideration for any supply for VAT purposes are deemed to be exclusive of any VAT
which is chargeable on that supply, and accordingly, subject to paragraph (b) below, if VAT is or becomes chargeable on any supply made by any Secured Party to any Party under a Finance Document and such Secured Party is required to account to
the relevant tax authority for the VAT, that Party must pay to such Secured Party (in addition to and at the same time as paying any other consideration for such supply) an amount equal to the amount of the VAT (and such Secured Party must promptly
provide an appropriate VAT invoice to that Party). 

  

	(b)	If VAT is or becomes chargeable on any supply made by any Secured Party (the “Supplier”) to any other Secured Party (the “Recipient”) under a Finance Document, and any Party other than the Recipient
(the “Relevant Party”) is required by the terms of any Finance Document to pay an amount equal to the consideration for that supply to the Supplier (rather than being required to reimburse or indemnify the Recipient in respect of that
consideration): 

  

	(i)	(where the Supplier is the person required to account to the relevant tax authority for the VAT) the Relevant Party must also pay to the Supplier (at the same time as paying that amount) an additional amount equal to
the amount of the VAT. The Recipient must (where this paragraph (i) applies) promptly pay to the Relevant Party an amount equal to any credit or repayment the Recipient receives from the relevant tax authority which the Recipient reasonably
determines relates to the VAT chargeable on that supply; and 

  

	(ii)	(where the Recipient is the person required to account to the relevant tax authority for the VAT) the Relevant Party must promptly, following demand from the Recipient, pay to the Recipient an amount equal to the VAT
chargeable on that supply but only to the extent that the Recipient reasonably determines that it is not entitled to credit or repayment from the relevant tax authority in respect of that VAT. 

 

	(c)	Where a Finance Document requires any Party to reimburse or indemnify a Secured Party for any cost or expense, that Party shall reimburse or indemnify (as the case may be) such Secured Party for the full amount of such
cost or expense, including such part of it as represents VAT, save to the extent that such Secured Party reasonably determines that it is entitled to credit or repayment in respect of such VAT from the relevant tax authority. 

 

	(d)	Any reference in this Clause 10.6 (VAT) to any Party being required to account to a tax authority for VAT shall, at any time when such Party is treated as a member of a group for VAT purposes, include a reference to
another member of that group being required to so account to the relevant tax authority. 

  

	(e)	In relation to any supply made by a Secured Party to any Party under a Finance Document, if reasonably requested by such Secured Party, that Party must promptly provide such Secured Party with details of that
Party’s VAT registration and such other information as is reasonably requested in connection with such Secured Party’s VAT reporting requirements in relation to such supply. 

  
 40 

 Execution Copy 

 

 10.7 Lender Status 
  

	(a)	Any Lender that is entitled to an exemption from or reduction of withholding Tax with respect to payments made under a Finance Document shall deliver to the Agent and the Borrower, at the time or times reasonably
requested by the Agent or the Borrower, such properly completed and executed documentation reasonably requested by the Agent or the Borrower (and which it is reasonable for the Lender to complete and execute) as will permit such payments to be made
without withholding or at a reduced rate of withholding. In addition, any Lender, if reasonably requested by the Agent or the Borrower, shall deliver such other documentation as prescribed by applicable law and reasonably requested by the Agent or
the Borrower as will enable the Agent or the Borrower to determine whether or not such Lender is subject to backup withholding or information reporting requirements. 

 

	(b)	Any Lender shall, to the extent it is legally entitled to do so, deliver to the Agent and the Borrower on or prior to the date on which such Lender becomes a Lender under this Agreement or promptly thereafter (and from
time to time thereafter as prescribed by applicable law or upon the request of the Agent or the Borrower), duly executed and properly completed copies of Internal Revenue Service Form W-9 or W-8, as applicable, certifying that it is not subject to
U.S. federal backup withholding or establishing an exemption from, or reduction of, U.S. federal withholding Tax. 

 10.8 FATCA Deduction

  

	(a)	Each Party may make any FATCA Deduction it is required to make by FATCA, and any payment required in connection with that FATCA Deduction, and no Party shall be required to increase any payment in respect of which it
makes such a FATCA Deduction or otherwise compensate the recipient of the payment for that FATCA Deduction. 

  

	(b)	Each Party shall promptly, upon becoming aware that it must make a FATCA Deduction (or that there is any change in the rate or the basis of such FATCA Deduction) notify the Party to whom it is making the payment and, in
addition, shall notify the Borrower, the Agent and the other Secured Parties. 

 10.9 FATCA Information 

 

	(a)	Subject to paragraph (c) below, each Party shall, within ten Business Days of a reasonable request by another Party: 

  

	(i)	confirm to that other Party whether it is: 

  

	(A)	a FATCA Exempt Party; or 

  

	(B)	not a FATCA Exempt Party; and 

  

	(ii)	supply to that other Party such forms, documentation and other information relating to its status under FATCA (including its applicable “passthru payment percentage” or other information required under the US
Treasury Regulations or other official guidance including intergovernmental agreements) as that other Party reasonably requests for the purposes of that other Party’s compliance with FATCA. 

 

	(b)	If a Party confirms to another Party pursuant to paragraph (a)(i) above that it is a FATCA Exempt Party and it subsequently becomes aware that it is not, or has ceased to be a FATCA Exempt Party, that Party shall notify
that other Party reasonably promptly. 

  
 41 

 Execution Copy 

 

	(c)	Paragraph (a) above shall not oblige any Creditor Party to do anything which would or might in its reasonable opinion constitute a breach of: 

 

	(i)	any law or regulation; 

  

	(ii)	any fiduciary duty; or 

  

	(iii)	any duty of confidentiality. 

  

	(d)	If a Party fails to confirm its status or to supply forms, documentation or other information requested in accordance with paragraph (a) above (including, for the avoidance of doubt, where paragraph (c) above
applies), then: 

  

	(i)	if that Party failed to confirm whether it is (and/or remains) a FATCA Exempt Party then such Party shall be treated for the purposes of the Finance Documents as if it is not a FATCA Exempt Party; and 

 

	(ii)	if that Party failed to confirm its applicable “passthru payment percentage” then such Party shall be treated for the purposes of the Finance Documents (and payments made thereunder) as if its applicable
“passthru payment percentage” is 100 per cent., 

 until (in each case) such time as the Party in question provides the
requested confirmation, forms, documentation or other information. 
 10.10 Increased Costs 

 

	(a)	If after the date of this Agreement by reason of (x) any change in law or in its interpretation or administration and/or (y) compliance with any request from or requirement of any central bank or other fiscal, monetary
or other authority including but without limitation the Basel Committee on Banking Regulations and Supervisory Practices whether or not having the force of law: 

  

	(i)	any of the Lenders incurs a cost as a result of its performing its obligations under this Agreement and/or its making available its Commitment hereunder; or 

 

	(ii)	there is any increase in the cost to any of the Lenders of funding or maintaining all or any of the advances comprised in a class of advances formed by or including its Commitment advanced or to be advanced by it
hereunder; or 

  

	(iii)	any of the Lenders incurs a cost as a result of its having entered into and/or its assuming or maintaining its commitment under this Agreement; or 

 

	(iv)	any of the Lenders becomes liable to make any payment on account of Tax or otherwise (other than Tax on its overall net income) on or calculated by reference to the amount of its Commitment advanced or to be advanced
hereunder and/or any sum received or receivable by it hereunder; or 

  

	(v)	any of the Lenders suffers any decrease in its rate of return as a result of any changes in the requirements relating to capital ratios, monetary control ratios, the payment of special deposits, liquidity costs or other
similar requirements affecting that Lender, 

 then the Borrower shall on demand pay to the Agent for the account of the relevant Lender or
Lenders amounts sufficient to indemnify the relevant Lender or Lenders against, as the case may be, such cost, such increased cost (or such proportion of such increased cost as is in the reasonable opinion of the relevant Lender or Lenders
attributable to the funding or maintaining of its or their Commitment(s) hereunder) or such liability. 

  
 42 

 Execution Copy 

 

	(b)	This Clause 10.10 (Increased Costs) does not apply to the extent any Increased Cost is: 

  

	(i)	Attributable to a Tax Deduction required by law to be made by an Obligor; 

  

	(ii)	Attributable to a FATCA Deduction required to be made by a Party; 

  

	(iii)	Compensated for by Clause 10.3 (Tax indemnity) (or would have been compensated for under Clause 10.3 (Tax indemnity) but was not compensated solely because any of the exclusions in Clause 10.3(b) applied);
or 

  

	(iv)	Attributable to the wilful breach by the relevant Creditor Party or its Affiliates of any law of regulation. 

In this Clause 10.10 (Increased Costs), a reference to a “Tax Deduction” has the same meaning given to the term in Clause 10.1
(Definitions). 
  

	(c)	A Lender affected by any provision of this Clause 10.10 (Increased Costs) shall promptly inform the Agent after becoming aware of the relevant change and its possible results (which notice shall be conclusive
evidence of the relevant change and its possible results) and the Agent shall, as soon as reasonably practicable thereafter, notify the Borrower of the change and its possible results. Without affecting the Borrower’s obligations under this
Clause 10.10 (Increased Costs) and in consultation with the Agent and the Italian Authorities, the affected Lender will then take all such reasonable steps as may be open to it to mitigate the effect of the change (for example (if then
possible) by changing its Facility Office or transferring some or all of its rights and obligations under this Agreement to another financial institution reasonably acceptable to the Borrower and the Agent and the Italian Authorities). The
reasonable costs of mitigating the effect of any such change shall be borne by the Borrower save where such costs are of an internal administrative nature and are not incurred in dealings by any Lender with third parties. 

10.11 Transaction Costs 
 The Borrower undertakes to pay
to the Agent, upon demand, all costs and expenses, duties and fees, including but without limitation agreed legal costs (which, for avoidance of doubt are exclusive of VAT and disbursements) out of pocket expenses and travel costs, reasonably
incurred by the Italian Authorities, the Joint Mandated Lead Arrangers and the Lenders (but not including any bank which becomes a Lender after the date of this Agreement) in connection with the negotiation, preparation and execution of all
agreements, guarantees, security agreements and related documents entered into, or to be entered into, for the purpose of the transaction contemplated hereby as well as all costs and expenses, duties and fees incurred by the Agent or the Lenders in
connection with the registration, filing, enforcement or discharge of the said guarantees or security agreements, including without limitation the fees and expenses of legal advisers and insurance experts and the fees and expenses of the Italian
Authorities (including the fees and expenses of its legal advisers) payable by the Joint Mandated Lead Arrangers to the Italian Authorities, the cost of registration and discharge of security interests and the related travel and out of pocket
expenses; the Borrower further undertakes to pay to the Agent all costs, expenses, duties and fees incurred by the Lenders and the Italian Authorities in connection with any variation of this Agreement and the related documents, guarantees and
security agreements, any supplements thereto and waiver given in relation thereto, in connection with the investigation of any potential Event of Default, the enforcement or preservation of any rights under this Agreement and/or the related
guarantees and security agreements, including in each case the fees and expenses of legal advisers, and in connection with the consultations or proceedings made necessary or in the opinion of the Agent desirable by the acts of, or failure to act on
the part of, the Borrower. 

  
 43 

 Execution Copy 

 

 10.12 Costs of delayed Delivery Date 

The Borrower undertakes to pay to the Agent, upon demand, any costs incurred by the Lenders and/or the Italian Authorities in funding the Loan in the event
that the Delivery Date is later than the Intended Delivery Date unless the Borrower has given the Agent at least three (3) Business Days’ notification of such delay in the Delivery Date. 

10.13 SACE obligations 
 To the extent that this Clause 10
(Taxes, Increased Costs, Costs and Related Charges) imposes obligations or restrictions on a Secured Party, such obligations or restrictions shall not apply to SACE and SACE shall have no obligations hereunder nor be constrained by such
restrictions. 
 11 REPRESENTATIONS AND WARRANTIES 

11.1 Timing and repetition 
 The following applies in
relation to the time at which representations and warranties are made and repeated: 
  

	(a)	the representations and warranties in Clause 11.2 (Continuing representations and warranties) are made on the date of this Agreement (apart from the representation at Clause 11.2 (dd) and 11.2 (ee) which shall
only be made on the date of this Agreement and shall not be repeated) and shall be deemed to be repeated, with reference mutatis mutandis to the facts and circumstances subsisting, as if made on each day until the Borrower has no remaining
obligations, actual or contingent, under or pursuant to this Agreement or any of the other Finance Documents; and 

  

	(b)	the representations and warranties in Clause 11.3 (Representations on the Delivery Date) are made on the Delivery Date and shall be deemed to be repeated, with reference mutatis mutandis to the facts and
circumstances subsisting, as if made thereafter on each day until the Borrower has no remaining obligations, actual or contingent, under or pursuant to this Agreement or any of the other Finance Documents. 

11.2 Continuing representations and warranties 
 The
Borrower represents and warrants to each of the Secured Parties that: 
  

	(a)	each Obligor is a limited liability company or body corporate duly organised, constituted and validly existing under the laws of the country of its formation or (as the case may be) incorporation, possessing perpetual
existence, the capacity to sue and be sued in its own name and the power to own and charge its assets and carry on its business as it is now being conducted; 

  

	(b)	the Borrower has an authorised 1000 Common Units all of which have been issued to Seven Seas. 

  

	(c)	the legal title to and beneficial interest in the equity in the Borrower is held free of any Security or any other claim by Seven Seas. 

 

	(d)	none of the equity in the Borrower is subject to any option to purchase, pre-emption rights or similar rights. 

  

	(e)	each Obligor has the power to enter into and perform this Agreement and those of the other Transaction Documents to which it is a party and the transactions contemplated hereby and thereby and has taken all necessary
action to authorise the entry into and performance of this Agreement and such other Transaction Documents and such transactions; 

  
 44 

 Execution Copy 

 

	(f)	this Agreement and each other Transaction Document constitutes (or will constitute when executed) legal, valid and binding obligations of each Obligor expressed to be a party thereto enforceable in accordance with their
respective terms and in entering into this Agreement and borrowing the Loan, the Borrower is acting on its own account; 

  

	(g)	the entry into and performance of this Agreement and the other Transaction Documents and the transactions contemplated hereby and thereby do not and will not conflict with: 

 

	(i)	any law or regulation or any official or judicial order; or 

  

	(ii)	the constitutional documents of any Obligor; or 

  

	(iii)	any agreement or document to which any Obligor is a party or which is binding upon such Obligor or any of its assets, 

nor result in the creation or imposition of any Security Interest on the Borrower or its assets pursuant to the provisions of any such agreement or document,
except for Security Interests which qualify as Permitted Security Interests with respect to the Borrower; 
  

	(h)	except for: 

  

	(i)	the filing of UCC-1 Financing Statements against the Borrower in respect of those Financing Documents to which it is a party and which create Security Interests; 

 

	(ii)	the recording of the Mortgage in the office of the Maritime Administrator of the Republic of the Marshall Islands; and 

  

	(iii)	the registration of the Ship under an Approved Flag, 

 all authorisations, approvals, consents, licences,
exemptions, filings, registrations, notarisations and other matters, official or otherwise, required in connection with the entry into, performance, validity and enforceability of this Agreement and each of the other Transaction Documents to which
any Obligor is a party and the transactions contemplated thereby have been obtained or effected and are in full force and effect except authorisations, approvals, consents, licences, exemptions, filings and registrations required in the normal day
to day course of the operation of the Ship and not already obtained by the Borrower; 
  

	(i)	it is disregarded as an entity separate from its owner for U.S. federal Tax purposes; 

  

	(j)	all information furnished by any Obligor relating to the business and affairs of any Obligor in connection with this Agreement and the other Transaction Documents was and remains true and correct in all material
respects and there are no other material facts or considerations the omission of which would render any such information misleading; 

  

	(k)	each Obligor has fully disclosed to the Agent all facts relating to each Obligor which it knows or should reasonably know and which might reasonably be expected to influence the Lenders in deciding whether or not to
enter into this Agreement; 

  

	(l)	the obligations of the Borrower and the Guarantors under the Finance Documents rank at least pari passu with all its other present unsecured and unsurbodinated indebtedness with the exception of any obligations which
are mandatorily preferred by law; 

  

	(m)	the Borrower is and shall remain, after the advance to it of the Loan, solvent in accordance with the laws of the state of Delaware and the United Kingdom and in particular with the provisions of the Insolvency Act 1986
(as from time to time amended) and the requirements thereof; 

  
 45 

 Execution Copy 

 

	(n)	neither the Borrower nor any other Obligor has taken any corporate action nor have any other steps been taken or legal proceedings been started or (to the best of its knowledge and belief) threatened against any of them
for the reorganisation, winding-up, dissolution or for the appointment of a liquidator, administrator, receiver, administrative receiver, trustee or similar officer of any of them or any or all of their assets or revenues nor has it sought any other
relief under any applicable insolvency or bankruptcy law; 

  

	(o)	the consolidated audited accounts of both Guarantors for the period ending on (in the case of Prestige Holdings) 31 December 2012 or (in the case of Seven Seas) 31 December 2012 or (in relation to any date on
which this representation and warranty is deemed to be repeated pursuant to Clause 11.1(a)) the latest available annual consolidated audited accounts of each Guarantor at the date of repetition (which accounts have been prepared in accordance with
GAAP) fairly represent the financial condition of each Guarantor as shown in such audited accounts; 

  

	(p)	none of the Obligors nor any of their respective assets enjoys any right of immunity (sovereign or otherwise) from set-off, suit or execution in respect of their obligations under this Agreement or any of the other
Transaction Documents or by any relevant or applicable law; 

  

	(q)	all the membership interest in the Borrower and all shares or membership interest in any Approved Manager which is a member of the Group shall be legally and beneficially owned directly or indirectly by (in the case of
the Borrower) Seven Seas and (in the case of such Approved Manager) Prestige Holdings and such structure shall remain so throughout the Security Period; 

  

	(r)	the copies of the Shipbuilding Contract, any External Management Agreement, any charter and any charter guarantee which require a notice of assignment to be served under the terms of the Tripartite General Assignment
(if any) and any other relevant third party agreements including but without limitation the copies of any documents in respect of the Insurances delivered to the Agent are true and complete copies of each such document constituting valid and binding
obligations of the parties thereto enforceable in accordance with their respective terms and, subject to Clauses 13.2 (Management and employment) and 12.22 (Shipbuilding Contract), no amendments thereto or variations thereof have been
agreed nor has any action been taken by the parties thereto which would in any way render such document inoperative or unenforceable; 

  

	(s)	any borrowing by the Borrower under this Agreement, and the performance of its obligations under this Agreement and the other Transaction Documents, will be for its own account and will not involve any breach by it of
any law or regulatory measure relating to “money laundering” as defined in Article 1 of the Directive (91/308/EEC) of the Council of the European Communities; and 

 

	(t)	no obligor is: 

  

	(i)	a Prohibited Person; 

  

	(ii)	is owned or controlled by or acting directly or indirectly on behalf of or for the benefit of, a Prohibited Person; or 

  

	(iii)	owns or controls a Prohibited Person; 

  

	(u)	no proceeds of the Loan shall be made available directly or indirectly to or for the benefit of a Prohibited Person nor shall they be otherwise directly or indirectly applied in a manner or for a purpose prohibited by
sanctions; 

  

	(v)	the choice of governing law of each Transaction Documents to which it is a party will be recognised and enforced in its Relevant Jurisdictions and any judgment obtained in relation to a Transaction Document to which it
is a party in the jurisdiction of the governing law of that Transaction Document will be recognised and enforced in its Relevant Jurisdictions; 

  
 46 

 Execution Copy 

 

	(w)	for the purposes of The Council of the European Union Regulation No. 1346/2000 on Insolvency Proceedings (the “Regulation”), its centre of main interest (as that term is used in Article 3(1) of the
Regulation) is situated outside of the European Union and it has no “establishment” (as that term is used in Article 2(h) of the Regulation) in European Union country; 

 

	(x)	no payments made or to be made by the Borrower or any Guarantor in respect of amounts due under this Agreement or any Finance Document have been or shall be funded out of funds of Illicit Origin and none of the sources
of funds to be used by the Borrower or the Guarantors in connection with the construction of the Ship or its business are of Illicit Origin; 

  

	(y)	to the best of the Borrower’s and each Guarantor’s knowledge, no Prohibited Payment has been or will be made or provided, directly or indirectly, by (or on behalf of) it, any of its affiliates, its or its
officers, directors or any other person acting on its behalf to, or for the benefit of, any authority (or any official, officer, director, agent or key employee of, or other person with management responsibilities in, of any authority) in connection
with the Ship, this Agreement and/or the Finance Documents; 

  

	(z)	no event has occurred which constitutes a default under or in respect of any Transaction Document to which any Obligor or the Builder is a party or by which any Obligor or the Builder may be bound (including (inter
alia) this Agreement) and no event has occurred which constitutes a default under or in respect of any agreement or document to which any Obligor is a party or by which any Obligor may be bound to an extent or in a manner which might have a material
adverse effect on the ability of that Obligor to perform its obligations under the Transaction Documents to which it is a party; 

  

	(aa)	none of the assets or rights of the Borrower is subject to any Security Interest except any Security Interest which qualifies as a Permitted Security Interest with respect to the Borrower; 

 

	(bb)	no litigation, arbitration or administrative proceedings are current or pending or, to its knowledge, threatened, which might, if adversely determined, have a material adverse effect on the ability of an Obligor to
perform its obligations under the Transaction Documents to which it is a party; 

  

	(cc)	to the best of its knowledge, each of the Obligors has complied with all taxation laws in all jurisdictions in which it is subject to Taxation and has paid all Taxes due and payable by it; 

 

	(dd)	it is not required to make any deduction for or on account of Tax from any payment it may make under any Finance Document to which it is a party with respect to any Lender that provides the documentation described in
Clause 10.7 (b) indicating that it is not subject to tax withholding; 

  

	(ee)	under the laws of its Relevant Jurisdictions it is not necessary that any stamp or similar taxes or fees be paid on or in relation to the Finance Documents to which it is a party or the transactions contemplated by
those Finance Documents; 

  

	(ff)	each member of the Group has good and marketable title to all its assets which are reflected in the audited accounts referred to in Clause 11.2(o); 

 

	(gg)	none of the Obligors has a place of business in any jurisdiction (except as already disclosed) which requires any of the Finance Documents to be filed or registered in that jurisdiction to ensure the validity of the
Finance Documents to which it is a party; 

  
 47 

 Execution Copy 

 

	(hh)	each of the Obligors and each member of the Group: 

  

	(i)	is in compliance with all Environmental Laws and Environmental Approvals provided that any non-compliance would not be expected to result in a Material Adverse Effect; 

 

	(ii)	has not received any notice or threat of any Environmental Claim against any member of the Group and no person has claimed that an Environmental Incident has occurred in each case that would reasonably be expected to
result in a Material Adverse Effect; 

  

	(iii)	confirms that no Environmental Incident has occurred and no person has claimed that an Environmental Incident has occurred in each case that would reasonably be expected to result in a Material Adverse Effect.

 11.3 Representations on the Delivery Date 

The Borrower further represents and warrants to each of the Secured Parties at Delivery that: 

 

	(a)	the Ship is in its absolute and unencumbered ownership save as contemplated by the Finance Documents; 

  

	(b)	the Ship is registered in its name under the laws and flag of the Maritime Registry; 

  

	(c)	the Ship is classed with the highest classification available for a Ship of its type free of all recommendations and qualifications with Lloyd’s Register, RINA or Bureau Veritas; 

 

	(d)	the Ship is operationally seaworthy and in compliance with all relevant provisions, regulations and requirements (statutory or otherwise) applicable to ships registered under the laws and flag of the Maritime Registry;

  

	(e)	the Ship is in compliance with the ISM Code, the ISPS Code and Annex VI as they relate to the Borrower, any Approved Manager and the Ship; 

 

	(f)	the Ship is insured in accordance with the provisions of Clause 14 (Insurance Undertakings) and in compliance with the requirements therein in respect of such insurances; and 

 

	(g)	the Ship is managed by the Approved Manager and, in the event that the Approved Manager is not a member of the Group, on and subject to the terms set out in the External Management Agreement. 

 

	(h)	there is no agreement or understanding to allow or pay any rebate, premium, inducement, commission, discount or other benefit or payment (however described) to the Borrower or any other member of the Group, the Builder
or a third party in connection with the purchase by the Borrower of the Ship, other than as disclosed to the Agent in writing on or before the date of this Agreement. 

 

	(i)	no Obligor has delivered particulars, whether in its name stated in the Finance Documents or any other name, of any UK Establishment to the Registrar of Companies as required under the Overseas Regulations or, if it has
so registered, it has provided to the Agent sufficient details to enable an accurate search against it to be undertaken by the Lenders at the Companies Registry. 

  
 48 

 Execution Copy 

 

 12 GENERAL UNDERTAKINGS 

12.1 General 
 The Borrower undertakes with each Secured
Party to comply with the following undertakings during the Security Period. 
 12.2 Information 

The Borrower will provide to the Agent for the benefit of the Lenders and SACE (or will procure the provision of): 

 

	(a)	as soon as practicable (and in any event within one hundred and twenty (120) days after the close of each of its financial years) a Certified Copy of the audited consolidated accounts of both Guarantors and their
subsidiaries for that year (commencing with accounts made up to 31 December 2012 in the case of the consolidated accounts of Prestige Holdings and up to 31 December 2012 in the case of the consolidated accounts of Seven Seas);

  

	(b)	as soon as practicable (and in any event within ninety (90) days of the commencement of each financial year) the budgetary forecast (profit and loss statement, balance sheet statement and cash flow statement) for
the two following years for each Guarantor; 

  

	(c)	as soon as practicable (and in any event within forty-five (45) days of the end of the contemplated quarter for the first three quarters in any fiscal year and within 90 days for the final quarter) a copy of the
unaudited consolidated quarterly management accounts (including current and year-to-date profit and loss statements and balance sheet compared to the previous year and to budget) of each Guarantor; 

 

	(d)	promptly, such further information in its possession or control regarding the condition or operations of the Ship and its financial condition and operations of the Borrower and those of any company in the Group as the
Agent may reasonably request for the benefit of the Secured Parties; and 

  

	(e)	details of any material litigation, arbitration or administrative proceedings (including proceedings relating to any alleged or actual breach of the ISM Code of the ISPS Code) which affect any company in the Group as
soon as the same are instituted and served, or, to the knowledge of the Borrower, threatened (and for this purpose proceedings shall be deemed to be material if they involve a claim in an amount exceeding twenty million Dollars or the equivalent in
another currency). 

 All accounts required under this Clause 12.2(Information) shall be prepared in accordance with GAAP and shall
fairly represent the financial condition of the relevant company. 
 12.3 Illicit Payments 

No payments made by the Borrower or any Guarantor in respect of amounts due under this Agreement or any Finance Document shall be funded out of funds of
Illicit Origin and none of the sources of funds to be used by the Borrower or the Guarantors in connection with the construction of the Ship or its business shall be of Illicit Origin 

12.4 Prohibited Payments 
 No Prohibited Payment shall be
made or provided, directly or indirectly, by (or on behalf of) the Borrower any Guarantor or any of their affiliates, officers, directors or any other person acting on its behalf to, or for the benefit of, any authority (or any official, officer,
director, agent or key employee of, or other person with management responsibilities in, of any authority) in connection with the Ship, this Agreement and/or the Finance Documents. 

  
 49 

 Execution Copy 

 

 12.5 Notification of default 

The Borrower will notify the Agent of any Event of Default forthwith upon becoming aware of the occurrence thereof. Upon the Agent’s request from time to
time the Borrower will issue a certificate stating whether any Obligor is aware of the occurrence of any Event of Default. 
 12.6 Consents and
registrations 
 The Borrower will procure that (and will promptly furnish Certified Copies to the Agent on the request of the Agent of) all such
authorisations, approvals, consents, licences and exemptions as may be required under any applicable law or regulation to enable it or any Obligor to perform its obligations under, and ensure the validity or enforceability of, each of the
Transaction Documents are obtained and promptly renewed from time to time and will procure that the terms of the same are complied with at all times. Insofar as such filings or registrations have not been completed on or before the Drawdown Date the
Borrower will procure the filing or registration within applicable time limits of each Finance Document which requires filing or registration together with all ancillary documents required to preserve the priority and enforceability of the Finance
Documents. 
 12.7 Negative pledge 
 The Borrower will
not create or permit to subsist any Security Interest on the whole or any part of its present or future assets, except for the following: 
  

	(a)	Security Interests created with the prior consent of the Agent; or 

  

	(b)	Security Interests qualifying as Permitted Security Interests with respect to the Borrower and described in paragraphs (a) and (b) of the definition of “Permitted Security Interests” in Clause 1.1
(Definitions); or 

  

	(c)	Security Interests qualifying as Permitted Security Interests with respect to the Borrower and described in paragraphs (C), (E), (H) or (I) of such definition, provided that insofar as they are enforceable
against the Ship they do not prevail over the Mortgage. 

 12.8 Disposals 

Except in the case of a sale of the Ship if the completion of the sale is contemporaneous with prepayment of the Loan in accordance with the provisions of
Clause 16.3 (Mandatory prepayment) and except for charters and other arrangements complying with Clause 13.1 (Pooling of earnings and charters) the Borrower shall not without the consent of the Majority Lenders, either in a single
transaction or in a series of transactions whether related or not and whether voluntarily or involuntarily, (i) sell, transfer, lease or otherwise dispose of the Ship or any of the Ship’s equipment except in the case of items
(a) being replaced (by an equivalent or superior item) or renewed or (b) that are being disposed of in the ordinary course of business provided that in the case of both (a) and (b) the net impact does not reduce the value
of the Ship and, in the case of (b), the value of any such disposals during the term of this Agreement do not, in aggregate, exceed US$3,000,000 (ii) sell, transfer or otherwise dispose of any of its receivables on recourse terms;
(iii) enter into any arrangement under which money or the benefit of a bank or other account may be applied, set off or made subject to a combination of accounts, or (iv) enter into any other preferential arrangement having the same effect
in circumstances where the arrangement or transaction is entered into primarily as a method of raising financial indebtedness or of financing the acquisition of an asset. 

  
 50 

 Execution Copy 

 

 12.9 Change of business 

Except with the prior consent of the Agent, the Borrower shall not make or threaten to make any substantial change in its business as presently conducted,
namely that of a single ship owning company for the Ship, or carry on any other business which is substantial in relation to its business as presently conducted so as to affect, in the opinion of the Agent, the Borrower’s ability to perform its
obligations hereunder. 
 12.10 Mergers 
 Except with
the prior consent of the Lenders and SACE, the Borrower will not enter into any amalgamation, restructure, substantial reorganisation, merger, de-merger or consolidation or anything analogous to the foregoing nor will it acquire any equity, share
capital or obligations of any corporation or other entity. 
 12.11 Maintenance of status and franchises 

The Borrower will do all such things as are necessary to maintain its limited liability company existence in good standing and will ensure that it has the
right and is duly qualified to conduct its business as it is conducted in all applicable jurisdictions and will obtain and maintain all franchises and rights necessary for the conduct of its business. 

12.12 Financial records 
 The Borrower will keep proper
books of record and account, in which proper and correct entries shall be made of all financial transactions and the assets, liabilities and business of the Borrower in accordance with GAAP. 

12.13 Financial Indebtedness and subordination of indebtedness 

The following restrictions shall apply: 
  

	(a)	otherwise than in the ordinary course of business as owner of the Ship, except as contemplated by this Agreement and except any loan, advance or credit extended by a Guarantor or any member of the Group which is a
wholly owned Subsidiary of Prestige Holdings, the Borrower will not create, incur, assume or allow to exist any financial indebtedness, enter into any finance lease or undertake any material capital commitment (including but not limited to the
purchase of any capital asset); and 

  

	(b)	the Borrower shall procure that any and all indebtedness (and in particular with any other Obligor) is at all times fully subordinated to the Finance Documents and the obligations of the Borrower hereunder. Upon the
occurrence of an Event of Default, the Borrower shall not make any repayments of principal, payments of interest or of any other costs, fees, expenses or liabilities arising from or representing such indebtedness. In this Clause 12.13(b) “fully
subordinated” shall mean that any claim of the lender against the Borrower in relation to such indebtedness shall rank after and be in all respects subordinate to all of the rights and claims of the Secured Parties under this Agreement and the
other Finance Documents and that the lender shall not take any steps to enforce its rights to recover any monies owing to it by the Borrower and in particular but without limitation the lender will not institute any legal or quasi-legal proceedings
under any jurisdiction at any time against the Ship, her Earnings or Insurances or the Borrower and it will not compete with the Secured Parties or any of them in a liquidation or other winding-up or bankruptcy of the Borrower or in any proceedings
in connection with the Ship, her Earnings or Insurances. 

  
 51 

 Execution Copy 

 

 12.14 Investments 

The Borrower shall not: 
  

	(a)	be the creditor in respect of any loan or any form of credit to any person other than another Obligor and where such loan or form of credit is Permitted Financial Indebtedness; 

 

	(b)	give or allow to be outstanding any guarantee or indemnity to or for the benefit of any person in respect of any obligation of any other person or enter into any document under which the Borrower assumes any liability
of any other person other than any guarantee or indemnity given under the Finance Documents. 

  

	(c)	enter into any material agreement other than: 

  

	(i)	the Transaction Documents; 

  

	(ii)	any other agreement expressly allowed under any other term of this Agreement; and 

  

	(d)	enter into any transaction on terms which are, in any respect, less favourable to the Borrower than those which it could obtain in a bargain made at arms’ length; or 

 

	(e)	acquire any shares or other securities other than US or UK Treasury bills and certificates of deposit issued by major North American or European banks. 

12.15 Unlawfulness, invalidity and ranking; Security imperilled 

No Obligor shall do (or fail to do) or cause or permit another person to do (or omit to do) anything which is likely to: 

 

	(a)	make it unlawful for an Obligor to perform any of its obligations under the Transaction Documents; 

  

	(b)	cause any obligation of an Obligor under the Finance Documents to cease to be legal, valid, binding or enforceable if that cessation individually or together with any other cessations materially or adversely affects the
interests of the Secured Parties under the Transaction Documents; 

  

	(c)	cause any Transaction Document to cease to be in full force and effect; 

  

	(d)	cause any Security Interest to rank after, or lose its priority to, any other Security Interest; and 

  

	(e)	imperil or jeopardise any Security Interest. 

 12.16 Dividends 

The Borrower shall not make or pay any dividend or other distribution (in cash or in kind) in respect of its share capital other than dividends and
distributions that are transferred to Seven Seas or Prestige provided that no Event of Default has occurred or is continuing or would result from the payment of any dividend. 

12.17 Loans and guarantees by the Borrower 
 Otherwise
than in the ordinary course of business in its ownership and operation of the Ship following the Delivery Date, the Borrower will not make any loan or advance or extend credit to any person, firm or corporation or issue or enter into any guarantee
or indemnity or otherwise become directly or contingently liable for the obligations of any other person, firm or corporation. 

  
 52 

 Execution Copy 

 

 12.18 Acquisition of shares 

The Borrower will not: 
  

	(a)	acquire any equity, share capital, assets or obligations of any corporation or other entity; or 

  

	(b)	permit any of its membership interest to be directly held other than by Seven Seas. 

 12.19 Further
assurance 
 The Borrower will, from time to time on being required to do so by the Agent, do or procure the doing of all such acts and/or execute or
procure the execution of all such documents in a form satisfactory to the Agent as the Agent may reasonably consider necessary for giving full effect to any of the Transaction Documents, the Interest Make-Up Agreement or the SACE Insurance Policy or
securing to the Secured Parties the full benefit of the rights, powers and remedies conferred upon the Secured Parties or any of them in any such Transaction Document the Interest Make-Up Agreement or the SACE Insurance Policy. 

12.20 Irrevocable payment instructions 
 The Borrower
shall not modify, revoke or withhold the payment instructions set out in Clause 4.1 (Borrower’s irrevocable payment instructions) without the agreement of the Builder (in the case of Clause 4.1(a) only), the Agent, SACE and the Lenders.

 12.21 “Know your customer” checks 
 If:

  

	(a)	the introduction of or any change in (or in the interpretation, administration or application of) any law or regulation made after the date of this Agreement; 

 

	(b)	any change in the status of the Borrower after the date of this Agreement; or 

  

	(c)	a proposed assignment or transfer by a Lender of any of its rights and obligations under this Agreement to a party that is not a Lender prior to such assignment or transfer, 

obliges the Agent or any Lender (or, in the case of Clause 12.21(c), any prospective new Lender) to comply with “know your customer” or similar
identification procedures in circumstances where the necessary information is not already available to it or the Lenders (acting reasonably) require any additional documents to supplement those already provided, the Borrower shall promptly upon the
request of the Agent or any Lender supply, or procure the supply of, such documentation and other evidence as is reasonably requested by the Agent (for itself or on behalf of any Lender) or any Lender (for itself or, in the case of the event
described in Clause 12.21(c), on behalf of any prospective new Lender) in order for the Agent and, such Lender or to carry out and be satisfied it has complied with all necessary “know your customer” or other similar checks under all
applicable laws and regulations pursuant to the transactions contemplated in the Finance Documents. 
  

	(d)	Each Lender shall promptly upon the request of a Servicing Party supply, or procure the supply of, such documentation and other evidence as is reasonably requested by the Servicing Party (for itself) in order for that
Servicing Party to carry out and be satisfied it has complied with all necessary “know your customer” or other similar checks under all applicable laws and regulations pursuant to the transactions contemplated in the Finance Documents.

  
 53 

 Execution Copy 

 

 12.22 Shipbuilding Contract 

The Shipbuilding Contract constitutes legal, valid and binding and enforceable obligations of the Builder and the Borrower shall not modify the Shipbuilding
Contract, directly or indirectly, if such modifications (in aggregate) would result in (i) a change to the type or class of the Ship or (ii) decrease the value of the Ship by equal to or greater than 5 per cent (in aggregate). The
Borrower will, therefore, submit to the Agent any proposals for any such modification and SACE and the Agent on behalf of the Lenders will indicate in a timely manner whether the modification proposed will allow the Loan to be maintained. On or
about the last day of each successive period of three (3) months commencing on the date of this Agreement and on the date of the Drawdown Notice, the Borrower undertakes to provide the Agent and SACE with a copy of any Change Order entered into
during that three (3) month or other period. The Borrower also undertakes to notify the Agent of any change in the Intended Delivery Date as soon as practicable after each change has occurred. 

12.23 FOREX Contracts 
 The Borrower shall: 

 

	(a)	provide the Agent with a copy of all FOREX Contracts together with all relevant details within twenty (20) days of their execution; and 

 

	(b)	inform the Agent, when requested by the Agent, of its intended hedging policy for purchasing Euro with Dollars. 

The Agent shall inform the Lenders within ten (10) days of receipt of such information from the Borrower. 

12.24 Compliance with laws etc. 
 The Borrower shall: 

 

	(a)	comply, or procure compliance with: 

  

	(i)	in all material respects, all laws and regulations relating to its business generally; and 

  

	(ii)	in all material respects (except in the case of compliance with Sanctions which must be complied with in all respects), all laws or regulations relating to the Ship, its ownership, employment, operation, management and
registration, 

 including the ISM Code, the ISPS Code, all Environmental Laws, all Sanctions and the laws of the Approved Flag; 

 

	(b)	obtain, comply with and do all that is necessary to maintain in full force and effect any Environment Approvals which are applicable to it; and 

 

	(c)	without limiting paragraph (a) above, not employ the Ship nor allow its employment, operation or management in any manner contrary to any law or regulation including but not limited to the ISM Code, the ISPS Code,
all Environmental Laws and all Sanctions. 

 13 SHIP UNDERTAKINGS 

13.1 Pooling of earnings and charters 
 The Borrower will
not without the prior written consent of the Agent or SACE enter into in respect of the Ship (such consent for the purposes of Clause 13.1(e) shall not be unreasonably withheld or delayed), nor permit to exist at any time following the Delivery
Date: 
  

	(a)	any pooling agreement or other arrangement for the sharing of any of the Earnings or the expenses of the Ship except with a member of the Group and provided that it does not adversely affect the rights of the Secured
Parties under the Finance Documents in the reasonable opinion of the Agent; or 

  
 54 

 Execution Copy 

 

	(b)	any demise or bareboat charter (other than the Seven Seas Charter), provided however that such consent shall not be unreasonably withheld in the event that the Borrower wishes to enter into a bareboat charter in a form
approved by the Agent with Seven Seas on condition that if so requested by the Agent and without limitation: 

  

	(i)	any such bareboat charterer shall enter into such deeds (including but not limited to a full subordination and assignment deed in respect of its rights under the bareboat charter and its interest in the Insurances and
earnings payable to it arising out of its use of the Ship), agreements and indemnities as the Majority Lenders shall require prior to entering into the bareboat charter with the Borrower; and 

 

	(ii)	the Borrower shall assign the benefit of any such bareboat charter and its interest in the Insurances to the Secured Parties by way of further security for the Borrower’s obligations under the Finance Documents.;
or 

  

	(c)	any charter whereunder two (2) months’ charterhire (or the equivalent thereof) is payable in advance in respect of the Ship; or 

 

	(d)	any charter of the Ship or employment which, with the exercise of options for extension, could be for a period longer than [*] months; or 

 

	(e)	any time charter of the Ship with a company outside the Group (other than a time charter entered into in the ordinary course of business which does not exceed two (2) months provided that any such time
charter (y) is assigned to the Security Trustee and (z) during the period of such time charter, the Ship continues to be managed by the existing Approved Manager), provided however that such consent shall not be unreasonably withheld in
the event that: 

  

	(i)	such time charter is assigned to the Security Trustee and the Borrower agrees to serve a notice of assignment of any time charter, the Earnings therefrom and any guarantee of the charterer’s obligations on the time
charterer and any time charter guarantor substantially in the form appended to the Tripartite General Assignment; 

  

	(ii)	the Agent and SACE are satisfied that the income from such time charter will be sufficient to cover the expenses of the Ship and to service repayment of the Loan and all other amounts from time to time outstanding under
this Agreement; and 

  

	(iii)	during the term of such time charter, the Ship continues to be managed by the existing Approved Manager. 

13.2 Management and employment 
 The Borrower will not as
from the Delivery Date: 
  

	(a)	permit any person other than an Approved Manager to be the manager of, including providing crewing services to, the Ship, at all times acting upon terms approved in writing by the Agent and having entered into (in the
case of the Approved Manager) an Approved Manager’s Undertaking; and 

  

	(b)	permit any amendment to be made to the terms of any External Management Agreement unless the amendment is advised by the Borrower’s tax counsel or is deemed necessary by the parties thereto to reflect the
prevailing circumstances but provided that the amendment does not imperil the security to be provided pursuant to the Finance Documents or adversely affect the ability of any Obligor to perform its obligations under the Transaction Documents; or

  

	(c)	permit the Ship to be employed other than within the Seven Seas brand unless the Borrower notifies the Lenders that they intend to employ the Ship within another brand of the Group and the ship remains employed within
the Group. 

  
 55 

 Execution Copy 

 

 13.3 Trading with the United States of America 

The Borrower shall in respect of the Ship take all reasonable precautions as from the Delivery Date to prevent any infringements of the Anti-Drug Abuse Act of
1986 of the United States of America (as the same may be amended and/or re-enacted from time to time hereafter) or any similar legislation applicable to the Ship in any other jurisdiction in which the Ship shall trade (a “Relevant
Jurisdiction”) where the Ship trades in the territorial waters of the United States of America or a Relevant Jurisdiction. 
 13.4 Valuation of
the Ship 
 The following shall apply in relation to the valuation of the Ship: 
  

	(a)	the Borrower will within 10 Business Days of the anniversary of the delivery of the Ship and at annual intervals thereafter unless an Event of Default has occurred and remains unremedied, at the Borrower’s expense,
procure that the Ship is valued by an Approved Broker (such valuation to be made without taking into account the benefit or otherwise of any fixed employment relating to the Ship); 

 

	(b)	the Borrower shall procure that forthwith upon the issuance of any valuation obtained pursuant to this Clause 13.4 (Valuation of the Ship) a copy thereof is sent directly to the Agent for review; and

  

	(c)	in the event that the Borrower fails to procure a valuation in accordance with Clause 1.1(a), the Agent shall be entitled to procure a valuation of the Ship on the same basis. 

13.5 Earnings 
 The Borrower will procure that the
Earnings (if any) are paid in full without set off and free and clear of and without deduction for any taxes levies duties imposts charges fees restrictions or conditions of any nature whatsoever. 

13.6 Operation and maintenance of the Ship 
 From the
Delivery Date until the end of the Security Period at its own expense the Borrower will keep the Ship in a good and efficient state of repair so as to maintain it to the highest classification notation available for the Ship of its age and type free
of all recommendations and qualifications with Lloyd’s Register, RINA or Bureau Veritas. On the Delivery Date and annually thereafter, it will furnish to the Agent a statement by such classification society that such classification notation is
maintained. It will comply with all recommendations, regulations and requirements (statutory or otherwise) from time to time applicable to the Ship and shall have on board as and when required thereby valid certificates showing compliance therewith
and shall procure that all repairs to or replacements of any damaged, worn or lost parts or equipment are carried out (both as regards workmanship and quality of materials) so as not to diminish the value or class of the Ship. It will not make any
substantial modifications or alterations to the Ship or any part thereof which would reduce the market and commercial value of the Ship determined in accordance with Clause 13.4 (Valuation of the Ship); 

  
 56 

 Execution Copy 

 

 13.7 Surveys and inspections 

The Borrower will: 
  

	(a)	submit the Ship to continuous survey in respect of its machinery and hull and such other surveys as may be required for classification purposes and, if so required by the Agent, supply to the Agent copies in English of
the survey reports; 

  

	(b)	permit surveyors or agents appointed by the Agent to board the Ship at all reasonable times to inspect its condition or satisfy themselves as to repairs proposed or already carried out and afford all proper facilities
for such inspections; 

 13.8 ISM Code 

The Borrower will comply, or procure that the Approved Manager will comply, with the ISM Code (as the same may be amended from time to time) or any replacement
of the ISM Code (as the same may be amended from time to time) and in particular, without prejudice to the generality of the foregoing, as and when required to do so by the ISM Code and at all times thereafter: 

 

	(i)	hold, or procure that the Approved Manager holds, a valid Document of Compliance duly issued to the Borrower or the Approved Manager (as the case may be) pursuant to the ISM Code and a valid Safety Management
Certificate duly issued to the Ship pursuant to the ISM Code; 

  

	(ii)	provide the Agent with copies of any such Document of Compliance and Safety Management Certificate as soon as the same are issued; and 

 

	(iii)	keep, or procure that there is kept, on board the Ship a copy of any such Document of Compliance and the original of any such Safety Management Certificate; 

13.9 ISPS Code 
 The Borrower will comply, or procure that
the Approved Manager will comply, with the ISPS Code (as the same may be amended from time to time) or any replacement of the ISPS Code (as the same may be amended from time to time) and in particular, without prejudice to the generality of the
foregoing, as and when required to do so by the ISPS Code and at all times thereafter: 
  

	(i)	keep, or procure that there is kept, on board the Ship the original of the International Ship Security Certificate required by the ISPS Code; and 

 

	(ii)	keep, or procure that there is kept, on board the Ship a copy of the ship security plan prepared pursuant to the ISPS Code; 

13.10 Annex VI 
 The Borrower will comply with Annex VI
(as the same may be amended from time to time) or any replacement of Annex VI (as the same may be amended from time to time) and in particular, without limitation, to: 
  

	(i)	procure that the Ship’s master and crew are familiar with, and that the Ship complies with, Annex VI; and 

  

	(ii)	maintain for the Ship throughout the Security Period a valid and current IAPPC and provide a copy to the Agent; and 

  

	(iii)	notify the Agent immediately in writing of any actual or threatened withdrawal, suspension, cancellation or modification of the IAPPC; 

  
 57 

 Execution Copy 

 

 13.11 Employment of Ship 

The Borrower shall: 
  

	(a)	not employ the Ship or permit its employment in any trade or business which is forbidden by any applicable law or is otherwise illicit or in carrying illicit or prohibited goods or in any manner whatsoever which may
render it liable to condemnation in a prize court or to destruction, seizure or confiscation or that may expose the Ship to penalties. In the event of hostilities in any part of the world (whether war be declared or not) it will not employ the Ship
or permit its employment in carrying any contraband goods; 

  

	(b)	promptly provide the Agent with (i) all information which the Agent may reasonably require regarding the Ship, its employment, earnings, position and engagements (ii) particulars of all towages and salvages
and (iii) copies of all charters and other contracts for its employment and otherwise concerning it; 

 13.12 Provision of information

 The Borrower shall give notice to the Agent promptly and in reasonable detail upon the Borrower or any other Obligor becoming aware of: 

 

	(i)	accidents to the Ship involving repairs the cost of which will or is likely to exceed $[*]; 

  

	(ii)	the Ship becoming or being likely to become a Total Loss; 

  

	(iii)	any recommendation or requirement made by any insurer or classification society or by any competent authority which is not complied with, or cannot be complied with, within any time limit relating thereto and that might
reasonably affect the maintenance of either the Insurances or the classification of the Ship; 

  

	(iv)	any writ or claim served against or any arrest of the Ship or the exercise of any lien or purported lien on the Ship, her Earnings or Insurances; 

 

	(v)	the Ship ceasing to be registered under the flag of the Maritime Registry or anything which is done or not done whereby such registration may be imperilled; 

 

	(vi)	it becoming impossible or unlawful for it to fulfil any of its obligations under the Finance Documents; and 

  

	(vii)	anything done or permitted or not done in respect of the Ship by any person which is likely to imperil the security created by the Finance Documents; 

13.13 Payment of liabilities 
  

	(a)	 The Borrower shall promptly pay and discharge all debts, damages and liabilities, taxes, assessments, charges, fines, penalties, tolls, dues and other
outgoings in respect of the Ship and keep proper books of account in respect thereof provided always that the Borrower shall not be obliged to compromise any debts, damages and liabilities as aforesaid which are being contested in good faith subject
always that full details of any such contested debt, damage or liability which, either individually or in aggregate exceeds $[*] shall forthwith be provided to the Agent. As and when the Agent may so require the Borrower will make such books
available for inspection on behalf of the Agent and provide evidence satisfactory to the Agent that the wages and allotments and the insurance and pension contributions of the master and crew are being regularly paid, that all deductions of
crew’s wages in respect of 

  
 58 

 Execution Copy 

 

	 	
any tax liability are being properly accounted for and that the master has no claim for disbursements other than those incurred in the ordinary course of trading on the voyage then in progress or
completed prior to such inspection; 

  

	(b)	promptly pay and discharge all liabilities which have given rise, or may give rise, to liens or claims enforceable against the Ship under the laws of all countries to whose jurisdiction the Ship may from time to time be
subject and in particular the Borrower hereby agrees to indemnify and hold the Secured Parties, their successors, assigns, directors, officers, shareholders, employees and agents harmless from and against any and all claims, losses, liabilities,
damages, expenses (including attorneys, fees and expenses and consultant fees) and injuries of any kind whatsoever asserted against the Secured Parties, with respect to or as a result of the presence, escape, seepage, spillage, release, leaking,
discharge or migration from the Ship or other properties owned or operated by the Borrower of any hazardous substance, including without limitation, any claims asserted or arising under any applicable environmental, health and safety laws, codes and
ordinances, and all rules and regulations promulgated thereunder of all governmental agencies, regardless of whether or not caused by or within the control of the Borrower subject to the following: 

 

	(i)	it is the parties’ understanding that the Secured Parties do not now, have never and do not intend in the future to exercise any operational control or maintenance over the Ship or any other properties and
operations owned or operated by the Borrower, nor in the past, presently, or intend in the future to, maintain an ownership interest in the Ship or any other properties owned or operated by the Borrower except as may arise upon enforcement of the
Lenders’ rights under the Mortgage; 

  

	(ii)	unless and until an Event of Default shall have occurred and without prejudice to the right of each Lender to be indemnified pursuant to this Clause 13.13(b): 

 

	(A)	each Lender will, if it is reasonably practicable to do so, notify the Borrower upon receiving a claim in respect of which the relevant Lender is or may become entitled to an indemnity under this Clause 13.13(b); and

  

	(B)	subject to the prior written approval of the relevant Lender which the Lender shall have the right to withhold, the Borrower will be entitled to take, in the name of the relevant Lender, such action as the Borrower may
see fit to avoid, dispute, resist, appeal, compromise or defend any such claims, losses, liabilities, damages, expenses and injuries as are referred to above in this Clause 13.13(b) or to recover the same from any third party, subject to the
Borrower first ensuring that the relevant Lender is secured to its reasonable satisfaction against all expenses thereby incurred or to be incurred; 

provided always that the Borrower shall not be obliged to compromise any liabilities as aforesaid which are being contested in good faith subject always that
full details of any such contested liabilities which, either individually or in aggregate, exceed $[*] shall be forthwith provided to the Agent. If the Ship is arrested or detained for any reason it will procure its immediate release by providing
bail or taking such other steps as the circumstances may require; 
 13.14 Certificate as to liabilities 

The Borrower shall give to the Agent at such times as it may from time to time reasonably require a certificate, duly signed on its behalf, as to the total
amount of any debts, damages and liabilities relating to the Ship and details of such of those debts, damages and liabilities as are over a certain amount to be specified by the Agent at the relevant time and, if so required by the Agent, forthwith
discharge such of those debts, damages and liabilities as the Agent shall require other than those being contested in good faith. 

  
 59 

 Execution Copy 

 

 13.15 Modifications 

The Borrower shall maintain the type of the Ship as at the Delivery Date and not put the Ship into the possession of any person for the purpose of work being
done on it in an amount exceeding or likely to exceed $[*] unless such person shall first have given to the Agent a written undertaking addressed to the Agent in terms satisfactory to the Agent agreeing not to exercise a lien on the Ship or her
Earnings for the cost of such work or for any other reason (or the Borrower is able to demonstrate to the reasonable satisfaction of the Agent that the Borrower or Seven Seas has set aside and will have funds readily available for payment when due
of the cost of the work (to the extent not fully covered by insurance proceeds in the case of a partial loss)); 
 13.16 Registration of Ship 

The Borrower shall maintain the registration of the Ship under and fly the flag of the Maritime Registry and not do or permit anything to be done whereby such
registration may be forfeited or imperilled. 
 13.17 Environmental Law 

The Borrower shall comply with all Environmental Laws, obtain, maintain and ensure compliance with all requisite Environmental Approvals, and implement
procedures to monitor compliance with and to prevent liability under any Environmental Law. 
 13.18 Notice of Mortgage 

The Borrower shall keep the Mortgage registered against the Ship as a valid first preferred mortgage, carry on board the Ship a certified copy of the Mortgage
and place and maintain in a conspicuous place in the navigation room and the master’s cabin of the Ship a framed printed notice stating that the Ship is mortgaged by the Borrower to the Security Trustee. 

13.19 Environmental claims 
 Each Obligor shall, (through
Prestige Holdings), promptly upon becoming aware of the same, inform the Agent in writing of: 
  

	(a)	any Environmental Claim which is likely to result in a Material Adverse Effect against any member of the Group which is current, pending or threatened; and 

 

	(b)	any facts or circumstances which are reasonably likely to result in any Environmental Claim being commenced or threatened against any member of the Group which is likely to result in a Material Adverse Effect.

 13.20 Trading in war zones 
 In the
event of hostilities in any part of the world (whether war is declared or not), the Borrower shall not cause or permit the Ship to enter or trade to any zone which is declared a war zone by the Ship’s war risks insurers unless: 

 

	(a)	the prior written consent of the Security Trustee acting on the instructions of the Majority Lenders has been given; and 

  

	(b)	the Borrower has (at its expense) effected any special, additional or modified insurance cover which the Security Trustee acting on the instructions of the Majority Lenders may require. 

  
 60 

 Execution Copy 

 

 14 INSURANCE UNDERTAKINGS 

14.1 General 
 The undertakings in this Clause 14
(Insurance Undertakings) remain in force on and from the Delivery Date and throughout the rest of the Security Period except as the Agent, acting with the authorisation of the Majority Lenders may otherwise permit. 

14.2 Maintenance of obligatory insurances 
 The Borrower
shall insure the Ship in its name and keep the Ship insured on an agreed value basis for an amount in the currency in which the Loan is denominated approved by the Agent but not being less than the greater of (x) [*]% of the amount of the Loan;
and (y) the full market and commercial value of the Ship determined in accordance with Clause 13.4 (Valuation of the Ship) from time to time through internationally recognised independent first class insurance companies, underwriters,
war risks and protection and indemnity associations acceptable to the Agent in each instance on terms and conditions approved by the Agent including as to deductibles but at least in respect of: 

 

	(i)	fire and marine risks including but without limitation hull and machinery and all other risks customarily and usually covered by first-class and prudent shipowners in the global insurance markets under English or
Norwegian marine policies or Agent-approved policies containing the ordinary conditions applicable to similar Ships; 

  

	(ii)	war risks (including terrorism, piracy and protection and indemnity war risks) up to the insured amount; 

  

	(iii)	excess risks that is to say the proportion of claims for general average and salvage charges and under the running down clause not recoverable in consequence of the value at which the Ship is assessed for the purpose of
such claims exceeding the insured value; 

  

	(iv)	protection and indemnity risks with full standard coverage as offered by first-class protection and indemnity associations which are a member of the International Group of P&I Association and up to the highest limit
of liability available (for oil pollution risk the highest limit currently available is one billion Dollars (USD1,000,000,000) and this to be increased if reasonably requested by the Agent and the increase is possible in accordance with the standard
protection and indemnity cover for Ships of its type and is compatible with prudent insurance practice for first class cruise shipowners or operators in waters where the Ship trades from time to time from the Delivery Date until the end of the
Security Period); 

  

	(v)	when and while the Ship is laid-up, in lieu of hull insurance, normal port risks; and 

  

	(vi)	such other risks as the Agent may from time to time reasonably require; 

 and in any event in respect of those
risks and at those levels covered by first class and prudent owners and/or financiers in the international market in respect of similar tonnage provided that if any of such insurances are also effected in the name of any other person (other than the
Borrower and/or a Secured Party) such person shall if so required by the Agent execute a first priority assignment of its interest in such insurances in favour of the Secured Parties in similar terms mutatis mutandis to the relevant provisions of
the Tripartite General Assignment; 

  
 61 

 Execution Copy 

 

 14.3 Mortgagee’s interest and pollution risks insurances 

The Agent shall take out mortgagee interest insurance on such conditions as the Agent may reasonably require and mortgagee interest insurance for pollution
risks as from time to time agreed each for an amount in the currency in which the Loan is denominated of [*]% of the amount of the Loan, the Borrower having no interest or entitlement in respect of such policies; the Borrower shall upon demand of
the Agent reimburse the Agent for the costs of effecting and/or maintaining any such insurance(s); 
 14.4 Trading in the United States of America

 If the Ship shall trade in the United States of America and/or the Exclusive Economic Zone of the United States of America (the
“EEZ”) as such term is defined in the US Oil Pollution Act 1990 (“OPA”), to comply strictly with the requirements of OPA and any similar legislation which may from time to time be enacted in any jurisdiction in
which the Ship presently trades or may or will trade at any time during the existence of this Agreement and in particular before such trade is commenced and during the entire period during which such trade is carried on: 

 

	(i)	to pay any additional premiums required to maintain full standard protection and indemnity cover for oil pollution up to the highest limit available to it for the Ship in the market; 

 

	(ii)	to make all such quarterly or other voyage declarations as may from time to time be required by the Ship’s protection and indemnity association and to comply with all obligations in order to maintain such cover,
and promptly to deliver to the Agent copies of such declarations; 

  

	(iii)	to submit the Ship to such additional periodic, classification, structural or other surveys which may be required by the Ship’s protection and indemnity insurers to maintain cover for such trade and promptly to
deliver to the Agent copies of reports made in respect of such surveys; 

  

	(iv)	to implement any recommendations contained in the reports issued following the surveys referred to in Clause 14.4(iii) within the time limit specified therein and to provide evidence satisfactory to the Agent that the
protection and indemnity insurers are satisfied that this has been done; 

  

	(v)	in particular strictly to comply with the requirements of any applicable law, convention, regulation, proclamation or order with regard to financial responsibility for liabilities imposed on the Borrower or the Ship
with respect to pollution by any state or nation or political subdivision thereof, including but not limited to OPA, and to provide the Agent on demand with such information or evidence as it may reasonably require of such compliance;

  

	(vi)	to procure that the protection and indemnity insurances do not contain a clause excluding the Ship from trading in waters of the United States of America and the EEZ or any other provision analogous thereto and to
provide the Agent with evidence that this is so; and 

  

	(vii)	strictly to comply with any operational or structural regulations issued from time to time by any relevant authorities under OPA so that at all times the Ship falls within the provisions which limit strict liability
under OPA for oil pollution; 

  
 62 

 Execution Copy 

 

 14.5 Protections for Secured Parties 

 

	(a)	The Borrower shall give notice forthwith of any assignment of its interest in the Insurances to the relevant brokers, insurance companies, underwriters and/or associations in the form approved by the Agent;

  

	(b)	The Borrower shall execute and deliver all such documents and do all such things as may be necessary to confer upon the Secured Parties legal title to the Insurances in respect of the Ship and to procure that the
interest of the Secured Parties is at all times filed with all slips, cover notes, policies and certificates of entry and to procure (a) that a loss payable clause in the form approved by the Agent shall be filed with all the hull, machinery
and equipment and war risks policies in respect of the Ship and (b) that a loss payable clause in the form approved by the Agent shall be endorsed upon the protection and indemnity certificates of entry in respect of the Ship; and

  

	(c)	In the event of the Borrower making default in insuring and keeping insured the Ship as hereinbefore provided then the Agent may (but shall not be bound to) insure the Ship or enter the Ship in such manner and to such
extent as the Agent in its discretion thinks fit and in such case all the cost of effecting and maintaining such insurance together with interest thereon at the Interest Rate shall be paid on demand by the Borrower to the Agent. 

14.6 Copies of polices; letters of undertaking 
 The
Borrower will procure that each of the relevant brokers and associations furnishes the Agent with a letter of undertaking in the standard form available in the relevant insurance market or otherwise in such form as may be required by the Agent and
waives any lien for premiums or calls except in relation to premiums or calls solely attributable to the Ship; 
 14.7 Payment of premiums 

The Borrower shall punctually pay all premiums, calls, contributions or other sums payable in respect of the Insurances on the Ship and to produce all relevant
receipts when so required by the Agent; 
 14.8 Renewal of obligatory insurances 

The Borrower shall notify the Agent of the renewal of the obligatory insurances at least five (5) days before the expiry thereof and shall procure that
the relevant brokers or associations shall promptly confirm in writing to the Agent that such renewal is effected it being understood by the Borrower that any failure to renew the Insurances on the Ship at least two (2) days before the expiry
thereof or to give or procure the relevant notices of such renewal shall constitute an Event of Default; 
 14.9 Guarantees 

The Borrower shall arrange for the execution of such guarantees as may from time to time be required by any protection and indemnity and/or war risks
association; 
 14.10 Provision of insurances information 

The Borrower will furnish the Agent from time to time on request with full information about all Insurances maintained on the Ship and the names of the
offices, companies, underwriters, associations or clubs with which such Insurances are placed; 
 14.11 Alteration to terms of insurances 

The Borrower shall not make or agree to any variation in the terms of any of the Insurances on the Ship without the prior approval of the Agent nor to do any
act or voluntarily suffer or 

  
 63 

 Execution Copy 

 

 
permit any act to be done whereby any Insurances shall or may be rendered invalid, void, voidable, suspended, defeated or unenforceable and not to suffer or permit the Ship to engage in any
voyage nor to carry any cargo not permitted under any of the Insurances without first obtaining the consent of the insurers or reinsurers concerned and complying with such requirements as to payment of extra premiums or otherwise as the insurers or
reinsurers may impose; 
 14.12 Settlement of claims 

The Borrower shall not settle, compromise or abandon any claim in respect of any of the Insurances on the Ship other than a claim of less than $[*] or the
equivalent in any other currency and not being a claim arising out of a Total Loss; 
 14.13 Application of insurance proceeds 

The Borrower shall apply or ensure the appliance of all such sums receivable in respect of the Insurances on the Ship for the purpose of making good the loss
and fully repairing all damage in respect whereof the insurance monies shall have been received; 
 14.14 Insurance advisers 

The Agent shall be entitled, immediately prior to the Delivery Date and thereafter no more frequently than annually on renewals but also additionally at any
time when there is a proposed change of underwriters or the terms of any Insurances, to instruct independent reputable insurance advisers for the purpose of obtaining any advice or information regarding any matter concerning the Insurances which the
Agent shall deem necessary, it being hereby specifically agreed that the Borrower shall reimburse the Agent on demand for the costs and expenses incurred by the Agent in connection with the instruction of such advisers subject to a limit of ten
thousand Euro at the time of delivery of the Ship or in the event of a change of underwriters or of terms of any Insurances and otherwise ten thousand Euro annually thereafter. 

15 SECURITY VALUE MAINTENANCE 
 15.1 Security Shortfall

 If, upon receipt of a valuation of the Ship in accordance with Clause 13.4 (Valuation of the Ship), the Security Value shall be less than the
Security Requirement, the Agent may give notice to the Borrower requiring that such deficiency be remedied and then the Borrower shall (unless the Ship has become a Total Loss) either: 

 

	(a)	prepay within a period of 30 days of the date of receipt by the Borrower of the Agent’s said notice such sum in Dollars as will result in the Security Requirement after such repayment (taking into account any other
repayment of the Loan made between the date of the notice and the date of such prepayment) being equal to the Security Value; or 

  

	(b)	within 30 days of the date of receipt by the Borrower of the Agent’s said notice constitute to the reasonable satisfaction of the Agent such further security for the Loan as shall be reasonably acceptable to the
Agent having a value for security purposes (as determined by the Agent in its absolute discretion) at the date upon which such further security shall be constituted which, when added to the Security Value, shall not be less than the Security
Requirement as at such date. 

 Clauses 15.2 (Costs) and 15.4 (Documents and evidence) and Clause 16.2(c) (Voluntary
prepayment) shall apply to prepayments under Clause 15.1(a). 

  
 64 

 Execution Copy 

 

 15.2 Costs 

All costs in connection with the Agent obtaining any valuation of the Ship referred to in Clause 13.4 (Valuation of the Ship), and obtaining any
valuation either of any additional security for the purposes of ascertaining the Security Value at any time or necessitated by the Borrower electing to constitute additional security pursuant to Clause 15.1(b) shall be borne by the Borrower. 

15.3 Valuation of additional security 
 For the purpose of
this Clause 15 (Security Value Maintenance), the market value of any additional security provided or to be provided to the Agent shall be determined by the Agent in its absolute discretion without any necessity for the Agent assigning any
reason thereto. 
 15.4 Documents and evidence 
 In
connection with any additional security provided in accordance with this Clause 15 (Security Value Maintenance), the Agent shall be entitled to receive such evidence and documents of the kind referred to in Clause 3 (Conditions
Precedent) in respect of other Finance Documents as may in the Agent’s opinion be appropriate. 
 15.5 Valuations binding 

Any valuation under this Clause 15 (Security Value Maintenance) shall be binding and conclusive as regards the Borrower. 

15.6 Provision of information 
  

	(a)	The Borrower shall promptly provide the Agent and any shipbroker acting under this Clause 15 (Security Value Maintenance) with any information which the Agent or the shipbroker may reasonably request for the
purposes of the valuation. 

  

	(b)	If the Borrower fails to provide the information referred to in paragraph (a) above by the date specified in the request, the valuation may be made on any basis and assumptions which the shipbroker or the Agent
considers prudent. 

 16 CANCELLATION, PREPAYMENT AND MANDATORY PREPAYMENT 

16.1 Cancellation 
 At any time prior to the delivery of a
Drawdown Notice and not less than ninety (90) Business Days prior to the Intended Delivery Date, the Borrower may give notice to the Agent in writing that it wishes to cancel the Total Commitments in their entirety whereupon (without penalty to
the Borrower but without prejudice to any liabilities of the Borrower including, without limitation, in respect of fees payable or accrued under this Agreement, arising prior to the date of such cancellation) the Total Commitments shall terminate
upon the date specified in such notice. 
 16.2 Voluntary prepayment 
  

	(a)	The Borrower may prepay all or part of the Loan (but if in part being an amount that reduces the Loan by a minimum amount of one (1) repayment instalment of principal of the Loan) together with interest thereon
without penalty provided that the prepayment is made on the last day of an Interest Period and forty five (45) days prior written notice indicating the intended date of prepayment is given to the Agent and the SACE Agent, but the following
amounts shall be payable to the Agent for the account of the Lenders or the Italian Authorities in the sum of: 

  

	(i)	if the Borrower has specified a Floating Interest Rate pursuant to Clause 3.5(a)(ii), the difference (if positive), calculated by the Lenders and notified by them to the Agent, between the actual cost for the Lenders of
the funding for the Loan and the rate of interest for the monies to be invested by the Lenders, applied to the amounts so prepaid for the period from the said prepayment until the last day of the Interest Period during which the prepayment occurs
(if prepayment does not occur on the last day of that Interest Period), details of any such calculation being supplied to the Borrower by the Agent on behalf of the Lenders; or 

 

	(ii)	if the Borrower has selected the Fixed Interest Rate pursuant to Clause 3.5(a)(ii), the charges (if any) imposed on the Lenders by the Italian Authorities representing funding or breakage costs of the Italian
Authorities as more specifically set out in Clause 20 (Indemnities). 

  
 65 

 Execution Copy 

 

	(b)	For the avoidance of doubt, if a voluntary prepayment is made other than on the last day of an Interest Period, the prepayment shall be paid together with such other amounts payable in accordance with Clause 20.1
(Indemnities regarding borrowing and repayment of Loan) and 20.2 (Breakage costs and SIMEST arrangements). 

  

	(c)	If the Borrower has selected the Fixed Interest Rate pursuant to Clause 3.5(a)(ii), the SACE Agent shall give SIMEST thirty (30) days written notice of the intended date of prepayment. 

16.3 Mandatory prepayment – Sale and Total Loss 
 The
Borrower shall be obliged to prepay the whole of the Loan if the Ship is sold or becomes a Total Loss: 
  

	(a)	in the case of a sale, on or before the date on which the sale is completed by delivery of the Ship to the buyer; or 

  

	(b)	in the case of a Total Loss, on the earlier of the date falling 120 days after the Total Loss Date and the date of receipt by the Agent of the proceeds of insurance relating to such Total Loss. 

16.4 Mandatory prepayment – SACE Insurance Policy 
  

	(a)	The Borrower shall be obliged to prepay the whole of the Loan if the SACE Insurance Policy is revoked, rescinded, cancelled, terminated, suspended or otherwise becomes unenforceable or ceases to be in full force and
effect. 

  

	(b)	In the event that any other event occurs or any other circumstances arise or develop which would have a Material Adverse Effect on SACE’s ability to perform its obligations under the SACE Insurance Policy, the
Borrower and the Lenders shall, provided that no Event of Default has occurred and is continuing, negotiate in good faith for a period of not less than 30 days with a view to agreeing such revised terms and conditions as the Lenders may require to
enable the Lenders to maintain the entire Loan (and during such 30 day period, no Lender shall be obliged to make available to the Borrower their portion of the Loan to the extent such amounts have not already been drawn). In the event that
following such negotiations the Borrower and the Lenders fail to agree on such revised terms, the Borrower shall be obliged to prepay, on demand by the Agent, the outstanding principal amount of the Loan to the extent of the amount covered pursuant
to the SACE Insurance Policy. If, during the period while negotiations are on-going pursuant to this Clause 16.4(b) the events described in Clause 16.4(a) should occur, the Borrower shall be obliged to prepay the Loan in full as required by Clause
16.4(a). 

 16.5 Mandatory repayment and cancellation of FATCA Protected Lenders 

If on the date falling six months before the earliest FATCA Application Date for any payment by a Party to a FATCA Protected Lender (or to the Agent for the
account of that Lender), that 

  
 66 

 Execution Copy 

 

 
Lender is not a FATCA Exempt Party and, in the opinion of that Lender (acting reasonably), that Party will, as a consequence, be required to make a FATCA Deduction from a payment to that Lender
(or to the Agent for the account of that Lender) on or after that FATCA Application Date (a “FATCA Event”); 
  

	(a)	that Lender shall, reasonably promptly after that date, notify the Agent of that FATCA Event and the relevant FATCA Application Date; 

 

	(b)	if, on the date falling one month before such FATCA Application Date, that FATCA Event is continuing: 

  

	(i)	that Lender may, no less than twenty (20) Business Days’ before such FATCA Application Date, notify the Agent; 

  

	(ii)	the Agent shall, by no less than seventeen (17) Business Days’ notice, notify the Borrower and, the Commitment of that Lender will be immediately cancelled upon the expiry of that seventeen (17) Business
Days’ notice period; and 

  

	(iii)	the Borrower shall repay that Lender’s participation in the Loan made to the Borrower on the last day of the Interest Period for the Loan occurring after the Agent has notified the Borrower or, if earlier, the last
Business Day before the relevant FATCA Application Date. 

 16.6 Other amounts 

Any prepayment of the whole of the Loan shall be made together with all other sums due under this Agreement (including, without limitation, the compensation
calculated in accordance with Clause 16.2 (Voluntary prepayment)). 
 16.7 Application of partial prepayment 

Amounts prepaid shall be applied in accordance with Clause 19.1.(b). 

16.8 No reborrowing 
 Amounts prepaid may not be
reborrowed. 
 17 INTEREST ON LATE PAYMENTS 
 17.1
Default rate of interest 
 Without prejudice to the provisions of Clause 18 (Events of Default) and without this Clause in any way constituting a
waiver of terms of payment, all sums due by the Borrower under this Agreement will automatically bear interest on a day to day basis from the date when they are payable until the date of actual payment at a rate per annum equal to the higher of:

  

	(a)	where the Floating Interest Rate is applicable, the aggregate of: 

  

	(i)	Overnight LIBOR; 

  

	(ii)	the Margin; and 

  

	(iii)	[*]% per annum; or 

  

	(b)	where the Fixed Interest Rate is applicable, the higher of: 

  

	(i)	the Fixed Interest Rate plus [*]% per annum; and 

  

	(ii)	Overnight LIBOR plus the Margin plus [*]% per annum. 

  
 67 

 17.2 Compounding of default interest 

Any such interest will itself bear interest at the above rate if it is due for at least three (3) months and thereafter at three monthly intervals. 

18 EVENTS OF DEFAULT 
 18.1 Events of Default 

An Event of Default occurs if any of the events or circumstances described in Clause 18.2 (Non-payment) to 18.20 (Material Adverse Change) occur.

 18.2 Non-payment 
 Any Obligor fails to pay when due
or (if so payable) on demand any sum payable under a Finance Document or under any document relating to a Finance Document and such failure is not remedied within three (3) Business Days of the due date or (if payable on demand) within three
(3) Business Days of receiving the demand. 
 18.3 Non-remediable breaches 

The Borrower fails to comply with the provisions of Clauses 12.7 (Negative pledge), 12.8 (Disposals), 12.10 (Mergers) or 12.17 (Loans
and guarantees by the Borrower). 
 18.4 Breach of other obligations 
  

	(a)	Any Obligor fails to comply with any provision of any Finance Document (other than a failure to comply covered by any of the other provisions of Clauses 18.2 (Non-payment) to 18.20 (Material Adverse Change) and in
particular but without limitation either of the Guarantors fails to comply with the provisions of Clause 11 (Undertakings) of its Guarantee or there is any breach in the opinion of the Majority Lenders of any of the Underlying Documents provided
that no Event of Default shall be deemed to have occurred if, in the opinion of the Majority Lenders, such failure or breach is capable of remedy and is remedied within the Relevant Period (as defined below) from the date of its occurrence, if the
failure was known to that Obligor, or from the date the relevant Obligor is notified by the Agent of the failure, if the failure was not known to that Obligor, unless in any such case as aforesaid the Majority Lenders consider that the failure or
breach is or could reasonably be expected to become materially prejudicial to the interests, rights or position of the Lenders, “Relevant Period” meaning for the purposes of this Clause thirty (30) days in respect of a remedy period
commencing under this Clause not later than 30 June 2015 and fifteen (15) days in respect of a remedy period commencing after 30 June 2015; or 

  

	(b)	If there is a repudiation or termination of any Transaction Document or if any of the parties thereto becomes entitled to terminate or repudiate any of them and evidences an intention so to do. 

18.5 Misrepresentation 
 Any representation, warranty or
statement made or repeated in, or in connection with, any Transaction Document or the SACE Insurance Policy or in any accounts, certificate, statement or opinion delivered by or on behalf of any Obligor thereunder or in connection therewith is
materially incorrect or misleading when made or would, if repeated at any time hereafter by reference to the facts subsisting at such time, no longer be materially correct. 

 Execution Copy 

 

 18.6 Cross default 
  

	(a)	Any event of default occurs under any financial contract or financial document relating to any Financial Indebtedness of the Borrower; or 

 

	(b)	any such Financial Indebtedness or any sum payable in respect thereof is not paid when due (after the expiry of any applicable grace period(s)) whether by acceleration or otherwise; or 

 

	(c)	any other Financial Indebtedness of any member of the Group is not paid when due or is or becomes capable of being declared due prematurely by reason of default or any Security Interest securing the same becomes
enforceable by reason of default provided that no Event of Default will arise if the aggregate amount of the relevant Financial Indebtedness and liabilities secured by the relevant Security Interests is less than $[*] or its equivalent in other
currencies; and 

  

	(d)	any other Security Interest over any assets of any member of the Group securing any alleged liability that does not qualify as Financial Indebtedness becomes enforceable where the alleged liability is in respect of a
sum of, or sum aggregating, $[*] or its equivalent in other currencies, unless the alleged liability is being contested in good faith by appropriate means by the relevant Group member and the Agent is reasonably satisfied that the relevant member of
the Group has reasonable grounds for succeeding in its action. 

 18.7 Winding-up 

Any order is made or an effective resolution passed or other action taken for the suspension of payments or reorganisation, dissolution, termination of
existence, liquidation, winding-up or bankruptcy of any Obligor. 
 18.8 Appointment of liquidators etc. 

A liquidator, trustee, administrator, receiver, administrative receiver, manager or similar officer is appointed in respect of any Obligor or in respect of all
or any substantial part of the assets of any Obligor. 
 18.9 Enforcement of any security 

Any corporate action, legal proceeding or other procedure or step is taken in relation to enforcement of any security interests over any assets of the
Borrower. 
 18.10 Insolvency 
  

	(a)	An Obligor is unable or admits inability to pay its debts as they fall due, is deemed to or declared to be unable to pay its debts under applicable law, suspends or threatens to suspend making payments on any of its
debts. 

  

	(b)	The value of the assets of any Obligor is less than its liabilities (taking into account contingent liabilities). 

  

	(c)	A moratorium in respect of all or any debts of any Obligor or a compromise, composition, assignment or an arrangement with creditors of any Obligor or any similar proceeding or arrangement by which the assets of any
Obligor are submitted to the control of its creditors is applied for, ordered or declared or any Obligor commences negotiations with any one or more of its creditors with a view to the general readjustment or rescheduling of all or a significant
part of its Financial Indebtedness. If a moratorium occurs, the ending of the moratorium will not remedy any Event of Default caused by that moratorium. 

  
 69 

 Execution Copy 

 

 18.11 Legal process 

Any corporate action, legal proceeding, distress, execution, attachment or other process affects the whole or any substantial part of the assets of any Obligor
and remains undischarged for a period of thirty (30) days, any step is taken in relation to enforcement of any security interests over any assets of any Obligor (other than the Borrower) or any uninsured judgment which, in each case, is in
excess of $[*] following final appeal, remains unsatisfied for a period of ten (10) days. 
 18.12 Analogous events 

Anything analogous to or having a substantially similar effect to any of the events specified in Clauses 18.7 (Winding-up) to 18.11 (Legal
process) shall occur under the laws of any applicable jurisdiction. 
 18.13 Cessation of business 

Any Obligor ceases to carry on all or a substantial part of its business. 

18.14 Revocation of consents 
 Any authorisation,
approval, consent, licence, exemption, filing, registration or notarisation or other requirement necessary to enable any Obligor to comply with any of its obligations under any of the Transaction Documents is materially adversely modified, revoked
or withheld or does not remain in full force and effect and within ninety (90) days of the date of its occurrence such event is not remedied to the satisfaction of the Agent and the Majority Lenders consider that such failure is or might be
expected to become materially prejudicial to the interests, rights or position of the Lenders provided that the Borrower shall not be entitled to the aforesaid ninety (90) day period if the modification, revocation or withholding of the
authorisation, approval or consent is due to an act or omission of any Obligor and the Majority Lenders are satisfied that the Lenders’ interests might reasonably be expected to be materially adversely affected. 

18.15 Unlawfulness 
 At any time it is unlawful or
impossible for any Obligor to perform any of its material (to the Secured Parties or any of them) obligations under any Transaction Document to which it is a party or it is unlawful or impossible for the Secured Parties or any Lender to exercise any
of their or its rights under any of the Transaction Documents provided that no Event of Default shall be deemed to have occurred where the unlawfulness or impossibility does not relate to the payment obligation of any Obligor under any Transaction
Document and is cured within the period of twenty one (21) days of the date of occurrence of the event giving rise to the unlawfulness or impossibility and the affected Obligor performs it obligation within such period. 

18.16 Insurances 
 The Borrower fails to insure the Ship
in the manner specified in Clause 14 (Insurance Undertakings) or fails to renew the Insurances at least five (5) days prior to the date of expiry thereof and produce prompt confirmation of such renewal to the Agent provided that if the
insurers withdraw their cover an Event of Default shall be deemed to have occurred upon issue of the insurer’s notice of withdrawal. 
 18.17
Disposals 
 If the Borrower or any other Obligor shall have concealed, removed, or permitted to be concealed or removed, any part of its property, with
intent to hinder, delay or defraud its creditors or any of them, or made or suffered a transfer of any of its property which may be 

  
 70 

 Execution Copy 

 

 
fraudulent under any bankruptcy, fraudulent conveyance or similar law; or shall have made any transfer of its property to or for the benefit of a creditor with the intention of preferring such
creditor over any other creditor. 
 18.18 Prejudice to security 

Anything is done or suffered or omitted to be done by any Obligor which in the reasonable opinion of the Agent would or might be expected to imperil the
security created by any of the Finance Documents. 
 18.19 Governmental intervention 

The authority of any Obligor in the conduct of its business is wholly or substantially curtailed by any seizure or intervention by or on behalf of any
authority and within ninety (90) days of the date of its occurrence any such seizure or intervention is not relinquished or withdrawn and the Agent reasonably considers that the relevant occurrence is or might be expected to become materially
prejudicial to the interests, rights or position of the Lenders provided that the Borrower shall not be entitled to the aforesaid ninety (90) day period if the seizure or intervention executed by any authority is due to an act or omission of
any Obligor and the Majority Lenders are satisfied that the Lenders’ interest might reasonably be expected to be materially adversely affected. 

18.20 Material Adverse Change 
 Any event or circumstance
occurs which results in a Material Adverse Effect. 
 18.21 Actions following an Event of Default 

On, or at any time after, the occurrence of an Event of Default the Agent may, and if so instructed by the Majority Lenders, the Agent shall with the prior
consent of SACE: 
  

	(a)	serve on the Borrower a notice stating that the Commitments and all other obligations of each Lender to the Borrower under this Agreement are terminated; and/or 

 

	(b)	serve on the Borrower a notice stating that the Loan (including but without limitation the amount representing the financed First Instalment and Second Instalment of the SACE Premium), all accrued interest and all other
amounts accrued or owing under this Agreement are immediately due and payable or are due and payable on demand; and/or 

  

	(c)	take any other action which, as a result of the Event of Default or any notice served under paragraph (a) or (b), the Agent and/or the Lenders are entitled to take under any Finance Document or any applicable law.

 18.22 Termination of Commitments 
 On
the service of a notice under Clause 18.21(a), the Commitments and all other obligations of each Lender to the Borrower under this Agreement shall terminate. 

18.23 Acceleration of Loan 
 On the service of a notice
under Clause 18.21(b), the Loan, all accrued interest and all other amounts accrued or owing from the Borrower or any Obligor under this Agreement and every other Finance Document shall become immediately due and payable or, as the case may be,
payable on demand. 

  
 71 

 Execution Copy 

 

 18.24 Further amounts payable 

Upon an acceleration of repayment of the Loan following an Event of Default the Borrower shall be liable to pay compensation calculated in accordance with
Clause 16.2 (Voluntary prepayment). 
 18.25 Multiple notices; action without notice 

The Agent may serve notices under Clauses 18.21(a) and (b) simultaneously or on different dates and it may take any action referred to in Clause 18.21(c)
if no such notice is served or simultaneously with or at any time after the service of both or either of such notices. 
 18.26 Notification of Secured
Parties and Obligors 
 The Agent shall send to the Italian Authorities, each Lender and each Obligor a copy or the text of any notice which the Agent
serves on the Borrower under Clause 18.21 (Actions following an Event of Default); but the notice shall become effective when it is served on the Borrower, and no failure or delay by the Agent to send a copy or the text of the notice to any
other person shall invalidate the notice or provide any Obligor with any form of claim or defence. 
 18.27 Lender’s rights unimpaired 

Nothing in this Clause 18 (Events of Default) shall be taken to impair or restrict the exercise of any right given to individual Lenders under a Finance
Document or the general law; and, in particular, this Clause is without prejudice to Clauses 2.4 (Creditor Parties’ rights and obligations) and 2.6 (Obligations of Lenders several). 

18.28 Exclusion of Secured Party liability 
 No Secured
Party, and no receiver or manager appointed by the Agent, shall have any liability to an Obligor: 
  

	(a)	for any loss caused by an exercise of rights under, or enforcement of a Security Interest created by, a Finance Document or by any failure or delay to exercise such a right or to enforce such a Security Interest; or

  

	(b)	as mortgagee in possession or otherwise, for any income or principal amount which might have been produced by or realised from any asset comprised in such a Security Interest or for any reduction (however caused) in the
value of such an asset. 

 19 APPLICATION OF SUMS RECEIVED 

19.1 Receipts 
 Except as any Finance Document may
otherwise provide, all sums received under this Agreement or any other Finance Document by the Agent, on behalf of the Lenders, or by any of the Lenders for any reason whatsoever will be applied: 

 

	(a)	in priority, to payments of any kind due or in arrears in the order of their due payment dates and first, to fees, charges and expenses, second, to interest payable pursuant to Clause 17 (Interest on Late Payments),
third, to interest payable pursuant to Clause 6 (Interest), fourth, to the principal of the Loan payable pursuant to Clause 5 (Repayment) and, fifth, to any other sums due under this Agreement or any other Finance Document and, if relevant, pro rata
to each of the Lenders; or 

  

	(b)	if no payments are in arrears or if these payments have been discharged as set out above, then and to sums remaining due under this Agreement or any other Finance Document and, if relevant, pro rata to each of the
Lenders and in each case in inverse order of maturity, the interest being recalculated accordingly. 

  
 72 

 Execution Copy 

 

 20 INDEMNITIES 

20.1 Indemnities regarding borrowing and repayment of Loan 

The Borrower shall fully indemnify the Agent and each Lender or SIMEST (but without double counting to the extent that a Lender is making a claim in respect of
amounts owing to SIMEST) on the Agent’s demand in respect of all claims, expenses, liabilities and losses which are made or brought against or incurred by that Secured Party, or which that Secured Party reasonably and with due diligence
estimates that it will incur, as a result of or in connection with: 
  

	(a)	the Loan not being borrowed on the date specified in the Drawdown Notice for any reason other than a default by the Lender claiming the indemnity; 

 

	(b)	the receipt or recovery of all or any part of the Loan or an overdue sum otherwise than on the last day of an Interest Period or other relevant period; 

 

	(c)	any failure (for whatever reason) by the Borrower to make payment of any amount due under a Finance Document on the due date or, if so payable, on demand (after giving credit for any default interest paid by the
Borrower on the amount concerned under Clause 17 (Interest on Late Payments)); and 

  

	(d)	the occurrence and/or continuance of an Event of Default and/or the acceleration of repayment of the Loan under Clause 18 (Events of Default). 

20.2 Breakage costs and SIMEST arrangements 
 Without
limiting its generality, Clause 20.1 covers: 
  

	(a)	any claim, expense, liability or loss, including a loss of a prospective profit, incurred by a Lender in liquidating or employing deposits from third parties acquired or arranged to fund or maintain all or any part of
its Contribution and/or any overdue amount (or an aggregate amount which includes its Contribution or any overdue amount); 

  

	(b)	if the Borrower has selected the Fixed Interest Rate in accordance with Clause 3.5(a)(ii), all of the amounts that SIMEST is entitled to charge, whether for taxes, costs, expenses, indemnities, penalties, losses or
liabilities whatsoever, under and in accordance with the Interest Make-up Agreement, including without limitation, as a result of any prepayment of all or any part of the Loan under this Agreement (whether voluntary, mandatory, following
acceleration of the Loan or otherwise), as a result of an Interest Make-Up Event or as a result of the Borrower deciding to switch from the Fixed Interest Rate to another interest rate after the Drawdown Date and/or (z) an Interest Make-up
Event . Such amounts include, without limitation, (i) breakage costs, (ii) any amount due as a consequence of the close-out of any hedging arrangement entered into by SIMEST in relation to this Agreement, (iii) default interest and
penalties (maggiorazioni) whenever applicable, and (iv) all amounts (if any) to be returned by the Agent to SIMEST under and pursuant to the Interest Make-Up Agreement; and 

 

	(c)	any other costs whatsoever or howsoever arising under or in respect of the Interest Make-Up Agreement which are passed to the Agent, 

any such costs imposed by SIMEST shall be paid by the Borrower to SIMEST through the Agent. 

  
 73 

 Execution Copy 

 

 For the purposes of this Clause 20.2 (Breakage costs and SIMEST arrangements) “Interest
Make-Up Event” means the occurrence of any circumstances which result in the termination, cancellation, revocation, cessation or suspension (in each case, in whole or in part) of the Interest Make-Up Agreement or the Interest Make-Up
Agreement otherwise ceases or may cease to be in full force and effect or the Agent notifies the Borrower that the Fixed Interest Rate is not available for any reason, in each case, in accordance with the terms of the Interest Make-Up Agreement.

 20.3 Miscellaneous indemnities 
 The Borrower shall
fully indemnify each Secured Party severally on their respective demands in respect of all claims, expenses, liabilities and losses which may be made or brought against or incurred by a Secured Party, in any country, as a result of or in connection
with: 
  

	(a)	any action taken, or omitted or neglected to be taken, under or in connection with any Finance Document by the Agent or any other Secured Party or by any receiver appointed under a Finance Document; 

 

	(b)	any other Pertinent Matter, 

 other than claims, expenses, liabilities and losses which are shown to have been
directly and mainly caused by the dishonesty or wilful misconduct of the officers or employees of the Secured Party concerned. 
 Without prejudice to its
generality, this Clause 20.3 (Miscellaneous indemnities) covers any claims, expenses, liabilities and losses which arise, or are asserted, under or in connection with any law relating to safety at sea, the ISM Code or any Environmental Laws
or any sanctions. 
 20.4 Currency indemnity 
 If any
sum due from an Obligor to a Creditor Party under a Finance Document or under any order or judgment relating to a Finance Document has to be converted from the currency in which the Finance Document provided for the sum to be paid (the
“Contractual Currency”) into another currency (the “Payment Currency”) for the purpose of: 
  

	(a)	making or lodging any claim or proof against an Obligor, whether in its liquidation, any arrangement involving it or otherwise; or 

  

	(b)	obtaining an order or judgment from any court or other tribunal; or 

  

	(c)	enforcing any such order or judgment, 

 the Borrower shall indemnify the Secured Party concerned against the
loss arising when the amount of the payment actually received by that Secured Party is converted at the available rate of exchange into the Contractual Currency. 

In this Clause 20.4 (Currency indemnity) the “available rate of exchange” means the rate at which the Secured Party concerned is able
at the opening of business (Paris time) on the Business Day after it receives the sum concerned to purchase the Contractual Currency with the Payment Currency. 

This Clause 20.4 (Currency indemnity) creates a separate liability of the Borrower which is distinct from its other liabilities under the Finance
Documents and which shall not be merged in any judgment or order relating to those other liabilities. 

  
 74 

 Execution Copy 

 

 20.5 Certification of amounts 

A notice which is signed by 2 officers of a Secured Party, which states that a specified amount, or aggregate amount, is due to that Secured Party under this
Clause 20 (Indemnities) and which indicates (without necessarily specifying a detailed breakdown) the matters in respect of which the amount, or aggregate amount, is due shall be prima facie evidence that the amount, or aggregate amount, is
due. 
 20.6 Sums deemed due to a Lender 
 For the
purposes of this Clause 20 (Indemnities), a sum payable by the Borrower to the Agent for distribution to a Lender shall be treated as a sum due to that Lender. 

21 ILLEGALITY, ETC. 
 21.1 Illegality 

This clause 21 (Illegality, etc.) applies if a Lender (the “Notifying Lender”) notifies the Agent that it has become, or will with
effect from a specified date, become: 
  

	(a)	unlawful or prohibited as a result of the introduction of a new law, an amendment to an existing law or a change in the manner in which an existing law is or will be interpreted or applied; or 

(b) contrary to, or inconsistent with, any regulation, 
 for the
Notifying Lender to maintain or give effect to any of its obligations under this Agreement in the manner contemplated by this Agreement. 
 21.2
Notification of illegality 
  

	(a)	The Agent shall promptly notify the Borrower, the Obligors and the other Lenders of the notice under Clause 21.1 (Illegality) which the Agent receives from the Notifying Lender. 

 

	(b)	Upon receipt of the notice under paragraph (a) above and provided that such illegality is not applicable with immediate effect (in which case Clause 21.3(a) (Prepayment; termination of Commitment) will apply
immediately and this Clause 21.2(b) (Notification of illegality) will not apply, the Agent shall, where the Borrower has selected the Fixed Interest Rate pursuant to Clause 3.5(a)(ii) inform SIMEST in writing in order to start consultations
between themselves (pursuant to clause 6 of the Interest Make-Up Agreement) with a view to exploring any possible solution to mitigate the unlawfulness preventing that Lender from performing any of its obligations under a Finance Document or funding
or maintaining its share in the Loan. Any solution agreed between the Agent and SIMEST at the end of the consultation period (which shall last for a period of ten (10) days from the service of such notice on SIMEST) will be binding among
themselves and shall be notified by the Agent to each Obligor immediately thereafter (and in any case no later than ten (10) days following such decision). 

  

	(c)	If at the end of the consultation procedure set out in paragraph (b) above, no solution is agreed between the Agent and SIMEST, the Agent must immediately notify the Lenders and the Obligors. 

 

	21.3	Prepayment; termination of Commitment 

  

	(a)	 After notification under paragraph (c) above or (in case the Interest Make-Up Agreement has ceased to be in force and effect or the Fixed
Interest Rate has not been selected pursuant to Clause 3.5(a)(ii)) after notification under paragraph (a) above and subject to Clause 21.4 below the Borrower must repay or prepay that Lender’s share in the Loan on the date

  
 75 

 Execution Copy 

 

	 	
specified in paragraph (c) below together with any Breakage Costs payable under Clause 20.2 (Breakage Costs and SIMEST Arrangements) and any indemnity payable under Clause 20.2(c) in respect
of the Interest Make-Up Agreement; 

  

	(b)	On the Agent notifying the Borrower under Clause 21.2(c) (Notification of illegality), the Notifying Lender’s Commitment shall terminate; and thereupon or, if later, on the date specified in the Notifying
Lender’s notice under Clause 21.1 (Illegality) as the date on which the notified event would become effective the Borrower shall prepay the Notifying Lender’s Contribution and shall pay compensation to the Notifying Lender
calculated in accordance with Clause 16.2 (Voluntary prepayment). 

  

	(c)	The date for repayment or prepayment of a Lender’s share in the Loan will be: 

  

	(i)	the date specified by the Agent in the notification under paragraph (b) above; or 

  

	(ii)	in case the Interest Make-Up Agreement has ceased to be in force and effect or the Fixed Interest Rate has not been selected pursuant to Clause 3.5(a)(ii), the last day of the current Interest Period for the Loan or, if
earlier, the date specified by the Lender in the notification under paragraph (a) above and which must not be earlier than the last day of any applicable grace period allowed by law. 

21.4 Mitigation 
  

	(a)	Each Secured Party shall, in consultation with the Borrowers, take all reasonable steps to mitigate any circumstances which arise and which would result in any amount becoming payable under or pursuant to, or cancelled
pursuant to Clause 21 (Illegality, etc.) including (but not limited to) transferring its rights and obligations under the Finance Documents to another Affiliate or Facility Office. 

 

	(b)	Paragraph (a) above does not in any way limit the obligations of any Obligor under the Finance Documents. 

  

	22	SET-OFF 

  

	22.1	Application of credit balances 

 Each Creditor Party may without prior notice: 

 

	(a)	apply any balance (whether or not then due) which at any time stands to the credit of any account in the name of the Borrower at any office in any country of that Creditor Party in or towards satisfaction of any sum
then due from the Borrower to that Creditor Party under any of the Finance Documents; and 

  

	(b)	for that purpose: 

  

	(i)	break, or alter the maturity of, all or any part of a deposit of the Borrower; 

  

	(ii)	convert or translate all or any part of a deposit or other credit balance into Dollars; 

  

	(iii)	enter into any other transaction or make any entry with regard to the credit balance which the Creditor Party concerned considers appropriate. 

 

	22.2	Existing rights unaffected 

 No Creditor Party shall be obliged to exercise any of its rights under
Clause 22.1 (Application of credit balances); and those rights shall be without prejudice and in addition to any right of set-off, combination of accounts, charge, lien or other right or remedy to which a Creditor Party is entitled (whether
under the general law or any document). 

  
 76 

 Execution Copy 

 

	22.3	Sums deemed due to a Lender 

 For the purposes of this Clause 22 (Set-Off), a sum payable by the
Borrower to the Agent for distribution to, or for the account of, a Lender shall be treated as a sum due to that Lender; and each Lender’s proportion of a sum so payable for distribution to, or for the account of, the Lenders shall be treated
as a sum due to such Lender. 
  

	22.4	No Security Interest 

 This Clause 22 (Set-Off) gives the Creditor Parties a contractual right of
set-off only, and does not create any equitable charge or other Security Interest over any credit balance of the Borrower. 
  

	23	CHANGES TO THE LENDERS 

 23.1 Transfer by a Lender 

Subject to Clause 23.5 (No transfer without Transfer Certificate), Clause 23.17 (Assignment or transfer to SACE) and Clause 23.14 (Change of
Facility Office), a Lender (the “Transferor Lender”) may at any time provided they have obtained the prior written consent of the Italian Authorities cause: 

 

	(a)	its rights in respect of all or part of its Contribution; or 

  

	(b)	its obligations in respect of all or part of its Commitment; or 

  

	(c)	a combination of (a) and (b), 

 to be (in the case of its rights) transferred to, or (in the case of its
obligations) assumed by, in whole or in part any of its Affiliates or another bank or financial institution or a trust, fund or other entity which is regularly engaged in or established for the purpose of making, purchasing or investing in loans,
securities or other financial assets (a “Transferee Lender”) by delivering to the Agent a completed certificate in the form set out in Schedule 4 with any modifications approved or required by the Agent (a “Transfer Certificate”)
executed by the Transferor Lender and the Transferee Lender. 
 However any rights and obligations of the Transferor Lender in its capacity as Agent or
Security Trustee will have to be dealt with separately in accordance with the provisions of Clause 25 (Role of the Agent and the Joint Mandated Lead Arrangers) and 26 (The Security Trustee) respectively. 

 

	23.2	Conditions of assignment or transfer 

  

	(a)	The consent of the Borrower is required at all times (subject to the provisions of Clause 23.5 (No transfer without Transfer Certificate) and 23.17 (Assignment or transfer to SACE) for an assignment or transfer
by an Existing Lender, unless (i) there is an Event of Default or (ii) the assignment or transfer is to another Lender or an Affiliate of a Lender. 

  

	(b)	The consent of the Borrower to an assignment or transfer must not be unreasonably withheld or delayed. The Borrower will be deemed to have given its consent ten (10) Business Days after the Existing Lender has
requested it unless consent is expressly refused by that Borrower within that time. 

  

	(c)	The assignment or transfer must be with respect to a minimum Commitment of $[*] or, if less, the Existing Lender’s full Commitment. 

  
 77 

 Execution Copy 

 

	23.3	Transfer Certificate, delivery and notification 

 As soon as reasonably practicable after a Transfer
Certificate is delivered to the Agent, it shall (unless it has reason to believe that the Transfer Certificate may be defective): 
  

	(a)	sign the Transfer Certificate on behalf of itself, the Borrower, any other Obligors, the Security Trustee and each of the other Lenders; 

 

	(b)	on behalf of the Transferee Lender, send to the Borrower and each Obligor letters or faxes notifying them of the Transfer Certificate and attaching a copy of it; and 

 

	(c)	send to the Transferee Lender copies of the letters or faxes sent under paragraph (b) above, 

 but the
Agent shall only be obliged to execute a Transfer Certificate delivered to it by the Transferor Lender and the Transferee Lender once it is satisfied it has complied with all necessary “know your customer” or other similar checks under all
applicable laws and regulations in relation to the transfer to that Transferee Lender. 
  

	23.4	Effective Date of Transfer Certificate 

 A Transfer Certificate becomes effective on the date, if any,
specified in the Transfer Certificate as its effective date, Provided that it is signed by the Agent under Clause 23.3 (Transfer Certificate, delivery and notification) on or before that date. 

 

	23.5	No transfer without Transfer Certificate 

 Except as provided in Clause 23.16 (Security over
Lenders’ rights), no assignment or transfer of any right or obligation of a Lender under any Finance Document is binding on, or effective in relation to, the Borrower, any Obligor, the Agent or the Security Trustee unless it is effected,
evidenced or perfected by a Transfer Certificate. 
  

	23.6	Lender re-organisation; waiver of Transfer Certificate 

 However, if a Lender enters into any merger,
de-merger or other reorganisation as a result of which all its rights or obligations vest in another person (the “successor”), the Agent may, if it sees fit, by notice to the successor and the Borrower and the Security Trustee waive
the need for the execution and delivery of a Transfer Certificate; and, upon service of the Agent’s notice, the successor shall become a Lender with the same Commitment and Contribution as were held by the predecessor Lender. 

 

	23.7	Effect of Transfer Certificate 

 A Transfer Certificate takes effect in accordance with English law as
follows: 
  

	(a)	to the extent specified in the Transfer Certificate, all rights and interests (present, future or contingent) which the Transferor Lender has under or by virtue of the Finance Documents are assigned to the Transferee
Lender absolutely, free of any defects in the Transferor Lender’s title and of any rights or equities which the Borrower or any Obligor had against the Transferor Lender; 

 

	(b)	the Transferor Lender’s Commitment is discharged to the extent specified in the Transfer Certificate; 

  

	(c)	the Transferee Lender becomes a Lender with the Contribution previously held by the Transferor Lender and a Commitment of an amount specified in the Transfer Certificate; 

 

	(d)	 the Transferee Lender becomes bound by all the provisions of the Finance Documents which are applicable to the Lenders generally, including those
about pro-rata sharing and the 

  
 78 

 Execution Copy 

 

	 	
exclusion of liability on the part of, and the indemnification of, the Agent and the Security Trustee and, to the extent that the Transferee Lender becomes bound by those provisions (other than
those relating to exclusion of liability), the Transferor Lender ceases to be bound by them; 

  

	(e)	any part of the Loan which the Transferee Lender advances after the Transfer Certificate’s effective date ranks in point of priority and security in the same way as it would have ranked had it been advanced by the
transferor, assuming that any defects in the transferor’s title and any rights or equities of the Borrower or any Obligor against the Transferor Lender had not existed; 

 

	(f)	the Transferee Lender becomes entitled to all the rights under the Finance Documents which are applicable to the Lenders generally, including but not limited to those relating to the Majority Lenders and those under
Clause 6.5 (Market disruption) and Clause 9 (Fees), and to the extent that the Transferee Lender becomes entitled to such rights, the Transferor Lender ceases to be entitled to them; and 

 

	(g)	in respect of any breach of a warranty, undertaking, condition or other provision of a Finance Document or any misrepresentation made in or in connection with a Finance Document, the Transferee Lender shall be entitled
to recover damages by reference to the loss incurred by it as a result of the breach or misrepresentation, irrespective of whether the original Lender would have incurred a loss of that kind or amount. 

The rights and equities of the Borrower or any Obligor referred to above include, but are not limited to, any right of set off and any other kind of
cross-claim. 
  

	23.8	Maintenance of register of Lenders 

 During the Security Period the Agent shall maintain a register in
which it shall record the name, Commitment, Contribution and administrative details (including the Facility Office) from time to time of each Lender holding a Transfer Certificate and the effective date (in accordance with Clause 23.4 (Effective
Date of Transfer Certificate)) of the Transfer Certificate; and the Agent shall make the register available for inspection by any Lender, the Security Trustee and the Borrower during normal banking hours, subject to receiving at least 3 Business
Days’ prior notice. 
  

	23.9	Reliance on register of Lenders 

 The entries on that register shall, in the absence of manifest error,
be conclusive in determining the identities of the Lenders and the amounts of their Commitments and Contributions and the effective dates of Transfer Certificates and may be relied upon by the Agent and the other parties to the Finance Documents for
all purposes relating to the Finance Documents. 
  

	23.10	Authorisation of Agent to sign Transfer Certificates 

 The Borrower, the Security Trustee and each Lender
irrevocably authorise the Agent to sign Transfer Certificates on its behalf. 
  

	23.11	Fees and Costs 

 In respect of any Transfer Certificate: 

 

	(a)	the Agent shall be entitled to recover a registration fee of EUR 5,000 from the Transferor Lender or (at the Agent’s option) the Transferee Lender; 

 

	(b)	 the Transferee Lender shall pay to the Agent, upon demand, all reasonable costs and expenses, duties and fees, including but without limitation legal
costs and out of pocket 

  
 79 

 Execution Copy 

 

	 	
expenses, incurred by the Agent or the Lenders in connection with any necessary amendment to or supplementing of the Transaction Documents or any of them or the SACE Insurance Policy as a
consequence of the assignment or transfer; and 

  

	(c)	the Transferee Lender shall pay to the Agent, upon demand, such amount as is payable to the Italian Authorities to cover its costs of giving its approval under Clause 23.1 (Transfer by a Lender).

  

	23.12	Sub-participation; subrogation assignment 

 A Lender may sub-participate all or any part of its rights
and/or obligations under or in connection with the Finance Documents without the consent of, or any notice to, the Borrower, any Obligor, the Agent or the Security Trustee but with the prior written consent of SACE. 

 

	23.13	Disclosure of information 

 A Lender may disclose to a potential Transferee Lender or sub participant any
information which the Lender has received in relation to the Borrower, any Obligor or their affairs under or in connection with any Finance Document, unless the information is clearly of a confidential nature. 

 

	23.14	Change of Facility Office 

 Subject to the prior written consent of SACE, a Lender may change its
Facility Office by giving notice to the Agent and the change shall become effective on the later of: 
  

	(a)	the date on which the Agent receives the notice; and 

  

	(b)	the date, if any, specified in the notice as the date on which the change will come into effect, provided that if (i) a Lender assigns or transfers any of its rights or obligations under the Finance Documents or
changes its Facility Office, and (ii) as a result of circumstances existing at the date the assignment, transfer or change occurs, an Obligor would be obliged to make a payment or an increased payment to the new Lender or Lender acting through
its new Facility Office under Clause 10 (Taxes, Increased Costs, Costs and Related Charges), then the new Lender or Lender acting through its new Facility Office is only entitled to receive payment under that Clause to the same extent as the
existing Lender or Lender acting through its previous Facility Office would have been if the assignment, transfer or change had not occurred. 

  

	23.15	Notification 

 On receiving such a notice, the Agent shall notify the Borrower and the Security Trustee;
and, until the Agent receives such a notice, it shall be entitled to assume that a Lender is acting through the Facility Office of which the Agent last had notice. 
  

	23.16	Security over Lenders’ rights 

 In addition to the other rights provided to Lenders under this
Clause 23 (Changes to the Lenders), each Lender may without consulting with or obtaining consent from the Borrower or any Obligor but subject to the prior written consent of SACE, at any time charge, assign or otherwise create a Security
Interest in or over (whether by way of collateral or otherwise) all or any of its rights under any Finance Document to secure obligations of that Lender (i) to the benefit of any Affiliate and/or (ii) within the framework of its, or its
Affiliates, direct or indirect funding operations including, without limitation: 
  

	(a)	any charge, assignment or other Security Interest to secure obligations to a federal reserve or central bank; and 

  

	(b)	in the case of any Lender which is a fund, any charge, assignment or other Security Interest granted to any holders (or trustee or representatives of holders) of obligations owed, or securities issued, by that Lender as
security for those obligations or securities; 

  
 80 

 Execution Copy 

 

 except that no such charge, assignment or Security Interest shall: 

 

	(i)	release a Lender from any of its obligations under the Finance Documents or substitute the beneficiary of the relevant charge, assignment or Security Interest for the Lender as a party to any of the Finance Documents;
or 

  

	(ii)	alter the obligations of the Obligor or require any payments to be made by the Borrower or any Obligor or grant to any person any more extensive rights than those required to be made or granted to the relevant Lender
under the Finance Documents. 

  

	23.17	Assignment or transfer to SACE 

 Notwithstanding the above provisions of this Clause 23 (Changes to
the Lenders): 
  

	(a)	each Lender and the Agent shall, if so instructed by SACE in accordance with the provisions of the SACE Insurance Policy and without any requirement for the consent of the Borrower, assign its rights or (as the case may
be) transfer its rights and obligations to SACE (but for the avoidance of doubt, SACE will not assume any of the Lenders’ obligations pursuant to clause 10 (Taxes, Increased Costs, Costs and Related Charges) or 32
(Confidentiality) of this Agreement), which assignment or transfer shall take effect upon the date stated in the relevant documentation; 

  

	(b)	the Agent shall promptly notify the Borrower of any such assignment or transfer to SACE and the Borrower shall pay to the Agent, upon demand, all reasonable costs and expenses, duties and fees, including but without
limitation legal costs and out of pocket expenses, incurred by the Agent or the Lenders in connection with any such assignment or transfer; 

  

	(c)	the Borrower and the Agent agree that SACE will be subrogated to the rights of the Lenders to the extent of any payment made by or on behalf of SACE under the SACE Insurance Policy. 

24 CHANGES TO THE OBLIGORS 
 24.1 No change without
consent 
 No Obligor may assign any of its rights or transfer any of its rights or obligations under the Finance Documents. 

25 ROLE OF THE AGENT AND THE JOINT MANDATED LEAD ARRANGERS 

25.1 Appointment of the Agent 
  

	(a)	Each other Creditor Party appoints the Agent to act as its agent under and in connection with this Agreement and the other Finance Documents, the SACE Insurance Policy and the Interest Make Up Agreement.

  

	(b)	Each other Creditor Party authorises the Agent to exercise the rights, powers, authorities and discretions specifically given to the Agent under or in connection with the Finance Documents together with any other
incidental rights, powers, authorities and discretions. 

 25.2 Duties of the Agent 

 

	(a)	The Agent shall promptly forward to a Party the original or a copy of any document which is delivered to the Agent for that Party by any other Party. 

  
 81 

 Execution Copy 

 

	(b)	Except where a Finance Document specifically provides otherwise, the Agent is not obliged to review or check the adequacy, accuracy or completeness of any document it forwards to another Party. 

 

	(c)	If the Agent receives notice from a Party referring to this Agreement, describing an Event of Default and stating that the circumstance described is an Event of Default, it shall promptly notify the other Secured
Parties. 

  

	(d)	If the Agent is aware of the non-payment of any principal, interest, commitment fee or other fee payable to a Secured Party (other than the Agent or a Joint Mandated Lead Arranger) under this Agreement it shall promptly
notify the other Creditor Parties. 

  

	(e)	The Agent’s duties under the Finance Documents are solely administrative in nature. 

 25.3 Role of the
Joint Mandated Lead Arrangers 
 None of the Joint Mandated Lead Arrangers has any obligations of any kind to any other Party under or in connection with
any Transaction Document, the Interest Make-Up Agreement or the SACE Insurance Policy. 
 25.4 No fiduciary duties 

 

	(a)	Nothing in this Agreement constitutes the Agent or any of the Joint Mandated Lead Arrangers as a trustee or fiduciary of any other person. 

 

	(b)	Neither the Agent nor any of the Joint Mandated Lead Arrangers shall be bound to account to any Lender for any sum or the profit element of any sum received by it for its own account. 

25.5 Business with the Guarantors 
 The Agent and each of
the Joint Mandated Lead Arrangers may accept deposits from, lend money to and generally engage in any kind of banking or other business with any Affiliate or Subsidiary of the Guarantors. 

25.6 Rights and discretions of the Agent 
  

	(a)	The Agent may rely on: 

  

	(i)	any representation, notice or document believed by it to be genuine, correct and appropriately authorised; and 

  

	(ii)	any statement made by a director, authorised signatory or employee of any person regarding any matters which may reasonably be assumed to be within his knowledge or within his power to verify. 

 

	(b)	The Agent may assume (unless it has received notice to the contrary in its capacity as agent for the Lenders) that: 

  

	(i)	no Event of Default has occurred (unless it has actual knowledge of an Event of Default); and 

  

	(ii)	any right, power, authority or discretion vested in any Party or the Lenders has not been exercised. 

  

	(c)	The Agent may engage, pay for and rely on the advice or services of any lawyers, accountants, surveyors or other experts. 

  
 82 

 Execution Copy 

 

	(d)	The Agent may act in relation to the Finance Documents through its personnel and agents. 

  

	(e)	The Agent may disclose to any other Party any information it reasonably believes it has received as the Agent under this Agreement. 

  

	(f)	Notwithstanding any other provision of any Finance Document to the contrary, neither the Agent nor any of the Joint Mandated Lead Arrangers is obliged to do or omit to do anything if it would or might in its reasonable
opinion constitute a breach of any law or regulation or a breach of a fiduciary duty or duty of confidentiality. 

 25.7 Lenders’
instructions 
  

	(a)	Unless a contrary indication appears in a Finance Document, the Agent shall: 

  

	(i)	exercise any right, power, authority or discretion vested in it as Agent in accordance with any instructions given to it by the Majority Lenders (or, if so instructed by the Majority Lenders, refrain from exercising any
right, power, authority or discretion vested in it as the Agent); and 

  

	(ii)	not be liable for any act (or omission) if it acts (or refrains from taking any action) in accordance with an instruction of the Majority Lenders. 

 

	(b)	Unless a contrary indication appears in a Finance Document, any instructions given by the Majority Lenders will be binding on all the Creditor Parties. 

 

	(c)	The Agent may refrain from acting in accordance with the instructions of the Majority Lenders until it has received such security as it may require for any cost, loss or liability (together with any associated VAT)
which it may incur in complying with the instructions. 

  

	(d)	In the absence of instructions from the Majority Lenders the Agent may act (or refrain from taking action) as it considers to be in the best interest of the Lenders. 

 

	(e)	The Agent is not authorised to act on behalf of a Lender (without first obtaining that Lender’s consent) in any legal or arbitration proceedings relating to any Finance Document. 

 

	(f)	Notwithstanding anything to the contrary, the Lenders agree that if the Agent (acting in its sole discretion) is of the opinion that or if any Lender notifies the Agent that it is of the opinion that, the prior approval
of the Italian Authorities should be obtained in relation to the exercise or non-exercise by the Agent or the Lenders of any power, authority or discretion specifically given to them under or in connection with the Finance Documents or in relation
to any other incidental rights, powers, authorities or discretions, then the Agent shall seek such approval of the Italian Authorities prior to such exercise or non-exercise. 

25.8 Responsibility for documentation 
 The Agent is not
responsible for: 
  

	(a)	the adequacy, accuracy and/or completeness of any information (whether oral or written) supplied by the Agent, a Joint Mandated Lead Arranger, an Obligor or any other person given in or in connection with any
Transaction Document, the SACE Insurance Policy or the Interest Make-Up Agreement; nor for 

  

	(b)	the legality, validity, effectiveness, adequacy or enforceability of any Transaction Document the SACE Insurance Policy or the Interest Make-Up Agreement or any other agreement, arrangement or document entered into,
made or executed in anticipation of or in connection with any Transaction Document, the SACE Insurance Policy or the Interest Make-Up Agreement. 

  
 83 

 Execution Copy 

 

 25.9 Exclusion of liability 
  

	(a)	Without limiting Clause 25.9(b), the Agent will not be liable for any action taken by it under or in connection with any Finance Document, the SACE Insurance Policy or the Interest Make-Up Agreement, unless directly
caused by its Gross Negligence or wilful misconduct. 

  

	(b)	No Party (other than the Agent) may take any proceedings against any officer, employee or agent of the Agent in respect of any claim it might have against the Agent or in respect of any act or omission of any kind by
that officer, employee or agent in relation to any Finance Document, the SACE Insurance Policy or the Interest Make-Up Agreement and any officer, employee or agent of the Agent may rely on this Clause subject to Clause 33.4 (Third party rights) and
the provisions of the Third Parties Rights Act. 

  

	(c)	The Agent will not be liable for any delay (or any related consequences) in crediting an account with an amount required under the Finance Documents, the SACE Insurance Policy or the Interest Make-Up Agreement to be
paid by the Agent if the Agent has taken all necessary steps as soon as reasonably practicable to comply with the regulations or operating procedures of any recognised clearing or settlement system used by the Agent for that purpose.

  

	(d)	Nothing in this Agreement shall oblige the Agent or a Joint Mandated Lead Arranger to carry out any “know your customer” or other checks in relation to any person on behalf of any Lender and each Lender
confirms to the Agent and the Joint Mandated Lead Arrangers that it is solely responsible for any such checks it is required to carry out and that it may not rely on any statement in relation to such checks made by the Agent or a Joint Mandated Lead
Arranger. 

 25.10 Lenders’ indemnity to the Agent 

Each Lender shall (in proportion to its share of the Total Commitments or, if the Total Commitments are then zero, to its share of the Total Commitments
immediately prior to their reduction to zero) indemnify the Agent, within three (3) Business Days of demand, against any cost, loss or liability incurred by the Agent (otherwise than by reason of the Agent’s Gross Negligence or wilful
misconduct) in acting as Agent under the Finance Documents (unless the Agent has been reimbursed by an Obligor pursuant to a Finance Document). 
 25.11
Resignation of the Agent 
  

	(a)	The Agent may resign and appoint one of its Affiliates as successor by giving notice to the other Creditor Parties, the Borrower and SACE and with the consent of SACE. 

 

	(b)	Alternatively the Agent may resign by giving notice to the other Creditor Parties and the Borrower, in which case the Lenders (after consultation with the Borrower) may appoint a successor Agent. 

 

	(c)	If the Lenders have not appointed a successor Agent in accordance with Clause 25.1(b) within thirty (30) days after notice of resignation was given, the Agent (after consultation with the Borrower) may appoint a
successor Agent. 

  

	(d)	The retiring Agent shall, at its own cost, make available to the successor Agent such documents and records and provide such assistance as the successor Agent may reasonably request for the purposes of performing its
functions as Agent under the Finance Documents. 

  

	(e)	The Agent’s resignation notice shall only take effect upon the appointment of a successor. 

  
 84 

 Execution Copy 

 

	(f)	Upon the appointment of a successor, the retiring Agent shall be discharged from any further obligation in respect of the Finance Documents but shall remain entitled to the benefit of this Clause 25 (Role of the
Agent and the Joint Mandated Lead Arrangers). Its successor and each of the other Parties shall have the same rights and obligations amongst themselves as they would have had if such successor had been an original Party. 

 

	(g)	After consultation with the Italian Authorities, the Majority Lenders may subject to the prior consent of the Italian Authorities, by notice to the Agent, require it to resign in accordance with Clause 25.11(b). In this
event, the Agent shall resign in accordance with Clause 25.11(b) but the cost referred to in paragraph (d) above shall be for the account of the Borrower. 

25.12 Confidentiality 
  

	(a)	In acting as agent for the Creditor Parties, the Agent shall be regarded as acting through its agency division which shall be treated as a separate entity from any other of its divisions or departments.

  

	(b)	If information is received by another division or department of the Agent, it may be treated as confidential to that division or department and the Agent shall not be deemed to have notice of it. 

25.13 Relationship with the Lenders 
 The Agent may treat
each Lender as a Lender, entitled to payments under this Agreement and acting through its Facility Office unless it has received not less than five (5) Business Days’ prior notice from that Lender to the contrary in accordance with the
terms of this Agreement. 
 25.14 Credit appraisal by the Lenders 

Without affecting the responsibility of any Obligor for information supplied by it or on its behalf in connection with any Finance Document, each Lender
confirms to the Agent and each of the Joint Mandated Lead Arrangers that it has been, and will continue to be, solely responsible for making its own independent appraisal and investigation of all risks arising under or in connection with any Finance
Document including but not limited to: 
  

	(a)	the financial condition, status and nature of the Guarantors and each Subsidiary of the Guarantors; 

  

	(b)	the legality, validity, effectiveness, adequacy or enforceability of any Finance Document and any other agreement, arrangement or document entered into, made or executed in anticipation of, under or in connection with
any Finance Document; 

  

	(c)	whether that Lender has recourse, and the nature and extent of that recourse, against any Party or any of its respective assets under or in connection with any Finance Document, the transactions contemplated by the
Finance Documents or any other agreement, arrangement or document entered into, made or executed in anticipation of, under or in connection with any Finance Document; 

 

	(d)	the adequacy, accuracy and/or completeness of any information provided by the Agent, any Party or by any other person under or in connection with any Finance Document, the transactions contemplated by the Finance
Documents or any other agreement, arrangement or document entered into, made or executed in anticipation of, under or in connection with any Finance Document; and 

 

	(e)	the right or title of any person in or to or the value or sufficiency of any part of the Charged Property, the priority of any Security Interests or the existence of any Security Interest affecting the Charged Property.

  
 85 

 Execution Copy 

 

	25.15	Deduction from amounts payable by the Agent 

 If any Party owes an amount to the Agent under the Finance
Documents the Agent may, after giving notice to that Party, deduct an amount not exceeding that amount from any payment to that Party which the Agent would otherwise be obliged to make under the Finance Documents and apply the amount deducted in or
towards satisfaction of the amount owed. For the purposes of the Finance Documents that Party shall be regarded as having received any amount so deducted. 

25.16 Full freedom to enter into transactions 

Notwithstanding any rule of law or equity to the contrary, the Agent shall be absolutely entitled: 

 

	(a)	to enter into and arrange banking, derivative, investment and/or other transactions of every kind with or affecting any Obligor or any person who is party to, or referred to in, a Finance Document (including, but not
limited to, any interest or currency swap or other transaction, whether related to this Agreement or not, and acting as syndicate agent and/or security agent for, and/or participating in, other facilities to such Obligor or any person who is party
to, or referred to in, a Finance Document); 

  

	(b)	to deal in and enter into and arrange transactions relating to: 

  

	(i)	any securities issued or to be issued by any Obligor or any other person; or 

  

	(ii)	any options or other derivatives in connection with such securities; and 

  

	(c)	to provide advice or other services to the Borrower or any person who is a party to, or referred to in, a Finance Document, 

and, in particular, the Agent shall be absolutely entitled, in proposing, evaluating, negotiating, entering into and arranging all such transactions and in
connection with all other matters covered by paragraphs (a), (b) and (c) above, to use (subject only to insider dealing legislation) any information or opportunity, howsoever acquired by it, to pursue its own interests exclusively, to
refrain from disclosing such dealings, transactions or other matters or any information acquired in connection with them and to retain for its sole benefit all profits and benefits derived from the dealings transactions or other matters. 

25.17 SACE Agent, SACE Insurance Policy and Interest Make-Up Agreement 
  

	(a)	Where the context permits, references to the Agent shall include the SACE Agent. The Agent and the SACE Agent shall be the same entity throughout the Security Period. 

 

	(b)	With the prior written consent of each of the Lenders, the SACE Agent may amend or modify the SACE Insurance Policy and the Interest Make-Up Agreement provided that such amendments are not inconsistent with the
commercial terms of this Agreement, otherwise, the SACE Agent undertakes not to amend or modify the SACE Insurance Policy or the Interest Make-Up Agreement. 

  
 86 

 Execution Copy 

 

 26 THE SECURITY TRUSTEE 

26.1 Trust 
  

	(a)	The Security Trustee declares that it shall hold the Security Property on trust for the Secured Parties on the terms contained in this Agreement and shall deal with the Security Property in accordance with this Clause
26 (The Security Trustee) and the other provisions of the Finance Documents. 

  

	(b)	Each of the parties to this Agreement agrees that the Security Trustee shall have only those duties, obligations and responsibilities expressly specified in this Agreement or in the Finance Documents (and no others
shall be implied). 

  

	(c)	The Security Trustee shall not have any liability to any person in respect of its duties, obligations and responsibilities under this Agreement or the other Finance Documents except as expressly set out in paragraph
(a) of Clause 26.1 (Trust) and as excluded or limited by this Clause 26 (The Security Trustee) including in particular Clause 26.8 (Instructions to Security Trustee and exercise of discretion), Clause 26.13
(Responsibility for documentation), Clause 26.14 (Exclusion of liability), Clause 26.16 (Lenders’ indemnity to the Security Trustee), Clause 26.23 (Business with the Group) and Clause 26.29 (Full freedom to enter
into transactions). 

 26.2 Parallel Debt (Covenant to pay the Security Trustee) 

 

	(a)	Each Obligor irrevocably and unconditionally undertakes to pay to the Security Trustee its Parallel Debt which shall be amounts equal to, and in the currency or currencies of, its Corresponding Debt. 

 

	(b)	The Parallel Debt of an Obligor: 

  

	(i)	shall become due and payable at the same time as its Corresponding Debt; 

  

	(ii)	is independent and separate from, and without prejudice to, its Corresponding Debt. 

  

	(c)	For purposes of this Clause 26.2 (Parallel Debt (Covenant to pay the Security Trustee)), the Security Trustee: 

  

	(i)	is the independent and separate creditor of each Parallel Debt; 

  

	(ii)	acts in its own name and not as agent, representative or trustee of the Secured Parties and its claims in respect of each Parallel Debt shall not be held on trust; and 

 

	(iii)	shall have the independent and separate right to demand payment of each Parallel Debt in its own name (including, without limitation, through any suit, execution, enforcement of security, recovery of guarantees and
applications for and voting in any kind of insolvency proceeding). 

  

	(d)	The Parallel Debt of an Obligor shall be: 

  

	(i)	decreased to the extent that its Corresponding Debt has been irrevocably and unconditionally paid or discharged; and 

  

	(ii)	increased to the extent that its Corresponding Debt has increased, 

 and the Corresponding Debt
of an Obligor shall be: 
  

	(A)	decreased to the extent that its Parallel Debt has been irrevocably and unconditionally paid or discharged; and 

  

	(B)	increased to the extent that its Parallel Debt has increased, 

 in each case provided that the Parallel Debt of
an Obligor shall never exceed its Corresponding Debt. 

  
 87 

 Execution Copy 

 

	(e)	All amounts received or recovered by the Security Trustee in connection with this Clause 26.2 (Parallel Debt (Covenant to pay the Security Trustee)) to the extent permitted by applicable law, shall be
applied in accordance with Clause 19 (Application of Sums Received). 

  

	(f)	This Clause 26.2 (Parallel Debt (Covenant to pay the Security Trustee)) shall apply, with any necessary modifications, to each Finance Document. 

26.3 No independent power 
 The Secured Parties shall not
have any independent power to enforce, or have recourse to, any Security Interest created by any of the Finance Documents or to exercise any rights or powers arising under the Finance Documents creating the Security Interest except through the
Security Trustee. 
 26.4 Application of receipts 
  

	(a)	Except as expressly stated to the contrary in any Finance Document, any moneys which the Security Trustee receives or recovers and which are, or are attributable to, Security Property (for the purposes of this Clause 26
(The Security Trustee), the “Recoveries”) shall be transferred to the Agent for application in accordance with Clause 19 (Application of Sums Received). 

 

	(b)	Paragraph (a) above is without prejudice to the rights of the Security Trustee, any receiver: 

  

	(i)	under Clause 25.10 (Lenders’ indemnity to the Agent) to be indemnified out of the Charged Property; and 

  

	(ii)	under any Finance Document to credit any moneys received or recovered by it to any suspense account. 

  

	(c)	Any transfer by the Security Trustee to the Agent in accordance with paragraph (a) above shall be a good discharge, to the extent of that payment, by the Security Trustee. 

 

	(d)	The Security Trustee is under no obligation to make the payments to the Agent under paragraph (a) of this Clause 26.4 (Application of receipts) in the same currency as that in which the obligations and
liabilities owing to the relevant Secured Party are denominated. 

 26.5 Deductions from receipts 

 

	(a)	Before transferring any moneys to the Agent under Clause 26.4 (Application of receipts), the Security Trustee may, in its discretion: 

 

	(i)	deduct any sum then due and payable under this Agreement or any other Finance Documents to the Security Trustee or any receiver and retain that sum for itself or, as the case may require, pay it to another person to
whom it is then due and payable; 

  

	(ii)	set aside by way of reserve amounts required to meet, and to make and pay, any deductions and withholdings (on account of Taxes or otherwise) which it is or may be required by any applicable law to make from any
distribution or payment made by it under this Agreement; and 

  

	(iii)	pay all Taxes which may be assessed against it in respect of any of the Security Property, or as a consequence of performing its duties, or by virtue of its capacity as Security Trustee under any of the Finance
Documents or otherwise (other than in connection with its remuneration for performing its duties under this Agreement). 

  

	(b)	For the purposes of paragraph (a)(i) above, if the Security Trustee has become entitled to require a sum to be paid to it on demand, that sum shall be treated as due and payable, even if no demand has yet been served.

  
 88 

 Execution Copy 

 

 26.6 Prospective liabilities 

Following acceleration of any Security Interest, the Security Trustee may, in its discretion, or at the request of the Agent, hold any recoveries in an
interest bearing suspense or impersonal account(s) in the name of the Security Trustee with such financial institution (including itself) and for so long as the Security Trustee shall think fit (the interest being credited to the relevant account)
for later payment to the Agent for application in accordance with Clause 19 (Application of Sums Received) in respect of: 
  

	(a)	any sum to the Security Trustee, any receiver; and 

  

	(b)	any part of the Secured Liabilities, 

 that the Security Trustee or, in the case of paragraph (b) only,
the Agent, reasonably considers, in each case, might become due or owing at any time in the future. 
 26.7 Investment of proceeds 

Prior to the payment of the proceeds of the recoveries to the Agent for application in accordance with Clause 19 (Application of Sums Received) the
Security Trustee may, in its discretion, hold all or part of those proceeds in an interest bearing suspense or impersonal account(s) in the name of the Security Trustee with such financial institution (including itself) and for so long as the
Security Trustee shall think fit (the interest being credited to the relevant account) pending the payment from time to time of those moneys in the Security Trustee’s discretion in accordance with the provisions of this 26.7 (Investment of
proceeds). 
 26.8 Instructions to Security Trustee and exercise of discretion 

 

	(a)	Subject to paragraph (d) below, the Security Trustee shall act in accordance with any instructions given to it by the Agent (acting on the instructions of the Majority Lenders or all the Lenders (as appropriate))
or, if so instructed by the Agent (acting on the instructions of the Majority Lenders or all the Lenders (as appropriate)), refrain from exercising any right, power, authority or discretion vested in it as Security Trustee and shall be entitled to
assume that: 

  

	(i)	any instructions received by it from the Agent (acting on the instructions of the Majority Lenders or all the Lenders (as appropriate)) are duly given in accordance with the terms of the Finance Documents; and (ii)

  

	(ii)	unless it has received actual notice of revocation, that those instructions or directions have not been revoked. 

  

	(b)	The Security Trustee shall be entitled to request instructions, or clarification of any direction, from the Agent (acting on the instructions of the Majority Lenders or all the Lenders (as appropriate)) as to whether,
and in what manner, it should exercise or refrain from exercising any rights, powers, authorities and discretions and the Security Trustee may refrain from acting unless and until those instructions or clarification are received by it.

  

	(c)	Any instructions given to the Security Trustee by the Agent (acting on the instructions of the Majority Lenders or all the Lenders (as appropriate)) shall override any conflicting instructions given by any other Party.

  

	(d)	Paragraph (a )above shall not apply: 

  

	(i)	where a contrary indication appears in this Agreement; 

  

	(ii)	where this Agreement requires the Security Trustee to act in a specified manner or to take a specified action; 

  
 89 

 Execution Copy 

 

	(iii)	in respect of any provision which protects the Security Trustee’s own position in its personal capacity as opposed to its role of Security Trustee for the Creditor Parties including, without limitation, the
provisions set out in Clauses 26.10 (Security Trustee’s discretions) to Clause 26.29 (Full freedom to enter into transactions); and 

  

	(iv)	in respect of the exercise of the Security Trustee’s discretion to exercise a right, power or authority under any of Clause 26.5 (Deductions from receipts) and Clause 26.6 (Prospective liabilities).

 26.9 Security Trustee’s Actions 

Without prejudice to the provisions of Clause 26.4 (Application of receipts), the Security Trustee may (but shall not be obliged to), in the absence of
any instructions to the contrary, take such action in the exercise of any of its powers and duties under the Finance Documents as it considers in its discretion to be appropriate. 

26.10 Security Trustee’s discretions 
  

	(a)	The Security Trustee may: 

  

	(i)	assume (unless it has received actual notice to the contrary from the Agent) that (i) no Event of Default has occurred and no Obligor is in breach of or default under its obligations under any of the Finance
Documents and (ii) any right, power, authority or discretion vested by any Finance Document in any person has not been exercised; 

  

	(ii)	assume that any notice or request made by the Borrower (other than the Drawdown Notice) is made on behalf of and with the consent and knowledge of all the Obligors; 

 

	(iii)	if it receives any instructions or directions to take any action in relation to a Security Interest under the Finance Documents, assume that all applicable conditions under the Finance Documents for taking that action
have been satisfied; 

  

	(iv)	engage, pay for and rely on the advice or services of any legal advisers, accountants, tax advisers, surveyors or other experts (whether obtained by the Security Trustee or by any other Secured Party) whose advice or
services may at any time seem necessary, expedient or desirable; 

  

	(v)	act in relation to the Finance Documents through its personnel and agents; 

  

	(vi)	disclose to any other Party any information it reasonably believes it has received as Security Trustee under this Agreement; 

  

	(vii)	rely upon any communication or document believed by it to be genuine and, as to any matters of fact which might reasonably be expected to be within the knowledge of a Secured Party or an Obligor, upon a certificate
signed by or on behalf of that person; and 

  

	(viii)	refrain from acting in accordance with the instructions of any Party (including bringing any legal action or proceeding arising out of or in connection with the Finance Documents) until it has received any
indemnification and/or security that it may in its discretion require (whether by way of payment in advance or otherwise) for all costs, losses and liabilities which it may incur in so acting. 

 

	(b)	Notwithstanding any other provision of any Finance Document to the contrary, the Security Trustee is not obliged to do or omit to do anything if it would or might, in its reasonable opinion, constitute a breach of any
law or regulation or a breach of a fiduciary duty or duty of confidentiality. 

  
 90 

 Execution Copy 

 

 26.11 Security Trustee’s obligations 

The Security Trustee shall promptly: 
  

	(a)	copy to the Agent the contents of any notice or document received by it from any Obligor under any Finance Document; 

  

	(b)	forward to a Party the original or a copy of any document which is delivered to the Security Trustee for that Party by any other Party provided that, except where a Finance Document expressly provides otherwise, the
Security Trustee is not obliged to review or check the adequacy, accuracy or completeness of any document it forwards to another Party; and 

  

	(c)	inform the Agent of the occurrence of any Event of Default or any default by an Obligor in the due performance of or compliance with its obligations under any Finance Document of which the Security Trustee has received
notice from any other party to this Agreement. 

 26.12 Excluded obligations 

Notwithstanding anything to the contrary expressed or implied in the Finance Documents, the Security Trustee shall not: 

 

	(a)	be bound to enquire as to (i) whether or not any Event of Default has occurred or (ii) the performance, default or any breach by an Obligor of its obligations under any of the Finance Documents;

  

	(b)	be bound to account to any other Party for any sum or the profit element of any sum received by it for its own account; 

  

	(c)	be bound to disclose to any other person (including but not limited to any Secured Party) (i) any confidential information or (ii) any other information if disclosure would, or might in its reasonable opinion,
constitute a breach of any law or be a breach of fiduciary duty; 

  

	(d)	have or be deemed to have any relationship of trust or agency with, any Obligor. 

 26.13 Responsibility for
documentation 
 None of the Security Trustee, any receiver shall accept responsibility or be liable for: 

 

	(a)	the adequacy, accuracy or completeness of any information (whether oral or written) supplied by the Security Trustee or any other person in or in connection with any Finance Document or the transactions contemplated in
the Finance Documents, or any other agreement, arrangement or document entered into, made or executed in anticipation of, under or in connection with any Finance Document; 

 

	(b)	the legality, validity, effectiveness, adequacy or enforceability of any Finance Document, the Security Property or any other agreement, arrangement or document entered into, made or executed in anticipation of, under
or in connection with any Finance Document or the Security Property; 

  

	(c)	any losses to any person or any liability arising as a result of taking or refraining from taking any action in relation to any of the Finance Documents, the Security Property or otherwise, whether in accordance with an
instruction from the Agent or otherwise unless directly caused by its Gross Negligence or wilful misconduct; 

  

	(d)	the exercise of, or the failure to exercise, any judgment, discretion or power given to it by or in connection with any of the Finance Documents, the Security Property or any other agreement, arrangement or document
entered into, made or executed in anticipation of, under or in connection with, the Finance Documents or the Security Property; or 

  

	(e)	any shortfall which arises on the enforcement or realisation of the Security Property. 

  
 91 

 Execution Copy 

 

 26.14 Exclusion of liability 
  

	(a)	Without limiting Clause 26.15 (No proceedings), none of the Security Trustee or any receiver will be liable for any action taken by it or not taken by it under or in connection with any Finance Document or any
Security Interest, unless directly caused by its Gross Negligence or wilful misconduct. 

  

	(b)	The Security Trustee will not be liable for any delay (or any related consequences) in crediting an account with an amount required under the Finance Documents to be paid by it if it has taken all necessary steps as
soon as reasonably practicable to comply with the regulations or operating procedures of any recognised clearing or settlement system used by it for that purpose. 

 

	(c)	Nothing in this Agreement shall oblige the Security Trustee to carry out any “know your customer” or other checks in relation to any person on behalf of any Lender and each Lender confirms to the Security
Trustee that it is solely responsible for any such checks it is required to carry out and that it may not rely on any statement in relation to such checks made by the Security Trustee. 

26.15 No proceedings 
 No Party (other than the Security
Trustee or that receiver) may take any proceedings against any officer, employee or agent of the Security Trustee or a receiver in respect of any claim it might have against the Security Trustee or a receiver in respect of any act or omission of any
kind by that officer, employee or agent in relation to any Finance Document or any Security Property and any officer, employee or agent of the Security Trustee or a receiver may rely on this Clause subject to Clause 33.4 (Third party rights)
and the provisions of the Third Parties Rights Act. 
 26.16 Lenders’ indemnity to the Security Trustee 

Each Lender shall (in proportion to its share of the Total Commitments or, if the Total Commitments are then zero, to its share of the Total Commitments
immediately prior to their reduction to zero) indemnify the Security Trustee and every receiver within three Business Days of demand, against any cost, loss or liability incurred by any of them (otherwise than by reason of the relevant Security
Trustee’s or receiver’s Gross Negligence or wilful misconduct) in acting as Security Trustee or receiver under the Finance Documents (unless the relevant Security Trustee or receiver has been reimbursed by an Obligor pursuant to a Finance
Document). 
 26.17 Own responsibility 
 Without
affecting the responsibility of any Obligor for information supplied by it or on its behalf in connection with any Finance Document, each Creditor Party confirms to the Security Trustee that it has been, and will continue to be, solely responsible
for making its own independent appraisal and investigation of all risks arising under or in connection with any Finance Document including but not limited to: 
  

	(a)	the financial condition, status and nature of each member of the Group; 

  

	(b)	the legality, validity, effectiveness, adequacy and enforceability of any Finance Document, the Security Property and any other agreement, arrangement or document entered into, made or executed in anticipation of, under
or in connection with any Finance Document or the Security Property; 

  
 92 

 Execution Copy 

 

	(c)	whether that Creditor Party has recourse, and the nature and extent of that recourse, against any Party or any of its respective assets under or in connection with any Finance Document, the Security Property, the
transactions contemplated by the Finance Documents or any other agreement, arrangement or document entered into, made or executed in anticipation of, under or in connection with any Finance Document or the Security Property; 

 

	(d)	the adequacy, accuracy and/or completeness of any information provided by the Security Trustee or by any other person under or in connection with any Finance Document, the transactions contemplated by any Finance
Document or any other agreement, arrangement or document entered into, made or executed in anticipation of, under or in connection with any Finance Document; and 

  

	(e)	the right or title of any person in or to, or the value or sufficiency of any part of the Charged Property, the priority of any of the Security Interests created by the Finance Documents or the existence of any Security
Interest affecting the Charged Property, 

 and each Creditor Party warrants to the Security Trustee that it has not relied on and will not at
any time rely on the Security Trustee in respect of any of these matters. 
 26.18 No responsibility to perfect Security Interests 

The Security Trustee shall not be liable for any failure to: 
  

	(a)	require the deposit with it of any deed or document certifying, representing or constituting the title of any Obligor to any of the Charged Property; 

 

	(b)	obtain any licence, consent or other authority for the execution, delivery, legality, validity, enforceability or admissibility in evidence of any of the Finance Documents or any Security Interest; 

 

	(c)	register, file or record or otherwise protect any Security Interests (or the priority of any of Security Interest) under any applicable laws in any jurisdiction or to give notice to any person of the execution of any of
the Finance Documents or of any Security Interest; 

  

	(d)	take, or to require any of the Obligors to take, any steps to perfect its title to any of the Charged Property or to render any Security Interest effective or to secure the creation of any ancillary Security under the
laws of any jurisdiction; or 

  

	(e)	require any further assurances in relation to any of the Finance Documents creating the Security Interests. 

26.19 Insurance by Security Trustee 
  

	(a)	The Security Trustee shall not be under any obligation to insure any of the Charged Property, to require any other person to maintain any insurance or to verify any obligation to arrange or maintain insurance contained
in the Finance Documents. The Security Trustee shall not be responsible for any loss which may be suffered by any person as a result of the lack of or inadequacy of any such insurance. 

 

	(b)	Where the Security Trustee is named on any insurance policy as an insured party, it shall not be responsible for any loss which may be suffered by reason of, directly or indirectly, its failure to notify the insurers of
any material fact relating to the risk assumed by such insurers or any other information of any kind, unless the Agent shall have requested it to do so in writing and the Security Trustee shall have failed to do so within fourteen (14) days
after receipt of that request. 

  
 93 

 Execution Copy 

 

 26.20 Custodians and nominees 

The Security Trustee may appoint and pay any person to act as a custodian or nominee on any terms in relation to any assets of the trust as the Security
Trustee may determine, including for the purpose of depositing with a custodian this Agreement or any document relating to the trust created under this Agreement and the Security Trustee shall not be responsible for any loss, liability, expense,
demand, cost, claim or proceedings incurred by reason of the misconduct, omission or default on the part of any person appointed by it under this Agreement or be bound to supervise the proceedings or acts of any person. 

26.21 Acceptance of title 
 The Security Trustee shall be
entitled to accept without enquiry, and shall not be obliged to investigate, any right and title that any of the Obligors may have to any of the Charged Property and shall not be liable for or bound to require any Obligor to remedy any defect in its
right or title. 
 26.22 Refrain from illegality 

Notwithstanding anything to the contrary expressed or implied in the Finance Documents, the Security Trustee may refrain from doing anything which in its
opinion will or may be contrary to any relevant law, directive or regulation of any jurisdiction and the Security Trustee may do anything which is, in its opinion, necessary to comply with any such law, directive or regulation. 

26.23 Business with the Group 
 The Security Trustee may
accept deposits from, lend money to, and generally engage in any kind of banking or other business with, any member of the Group. 
 26.24 Winding up of
trust 
 If the Security Trustee, with the approval of the Agent determines that (a) all of the Secured Liabilities and all other obligations
secured by the Finance Documents creating the Security Interests have been fully and finally discharged and (b) none of the Secured Parties is under any commitment, obligation or liability (actual or contingent) to make advances or provide
other financial accommodation to any Obligor pursuant to the Finance Documents: 
  

	(a)	the trusts set out in this Agreement shall be wound up and the Security Trustee shall release, without recourse or warranty, all of the Security Interests and the rights of the Security Trustee under each of the Finance
Documents creating the Security Interests; and 

  

	(b)	any Retiring Security Trustee shall release, without recourse or warranty, all of its rights under each of the Finance Documents creating the Security Interests. 

26.25 Perpetuity period 
 The trusts constituted by this
Agreement are governed by English law and the perpetuity period under the rule against perpetuities, if applicable to this Agreement, shall be the period of 125 years from the date of this Agreement. 

26.26 Powers supplemental 
 The rights, powers and
discretions conferred upon the Security Trustee by this Agreement shall be supplemental to the Trustee Act 1925 and the Trustee Act 2000 and in addition to any which may be vested in the Security Trustee by general law or otherwise. 

  
 94 

 Execution Copy 

 

 26.27 Trustee division separate 

 

	(a)	In acting as trustee for the Secured Parties, the Security Trustee shall be regarded as acting through its trustee division which shall be treated as a separate entity from any of its other divisions or departments.

  

	(b)	If information is received by another division or department of the Security Trustee, it may be treated as confidential to that division or department and the Security Trustee shall not be deemed to have notice of it
nor shall it be obliged to disclose such information to any Party. 

 26.28 Disapplication 

In addition to its rights under or by virtue of this Agreement and the other Finance Documents, the Security Trustee shall have all the rights conferred on a
trustee by the Trustee Act 1925, the Trustee Delegation Act 1999, the Trustee Act 2000 and by general law or otherwise, provided that: 
  

	(a)	section 1 of the Trustee Act 2000 shall not apply to the duties of the Security Trustee in relation to the trusts constituted by this Agreement and the other Finance Documents; and 

 

	(b)	where there are any inconsistencies between (i) the Trustee Acts 1925 and 2000 and (ii) the provisions of this Agreement and any other Finance Document, the provisions of this Agreement and any other Finance
Document shall, to the extent allowed by law, prevail and, in the case of any inconsistency with the Trustee Act 2000, such provisions shall constitute a restriction or exclusion for the purposes of the Trustee Act 2000. 

26.29 Full freedom to enter into transactions 

Notwithstanding any rule of law or equity to the contrary, the Security Trustee shall be absolutely entitled: 

 

	(a)	to enter into and arrange banking, derivative, investment and/or other transactions of every kind with or affecting any Obligor or any person who is party to, or referred to in, a Finance Document (including, but not
limited to, any interest or currency swap or other transaction, whether related to this Agreement or not, and acting as syndicate agent and/or security trustee for, and/or participating in, other facilities to such Obligor or any person who is party
to, or referred to in, a Finance Document); 

  

	(b)	to deal in and enter into and arrange transactions relating to: 

  

	(i)	any securities issued or to be issued by any Obligor or any other person; or 

  

	(ii)	any options or other derivatives in connection with such securities; and 

  

	(c)	to provide advice or other services to the Borrower or any person who is a party to, or referred to in, a Finance Document, in particular, each Servicing Party shall be absolutely entitled, in proposing, evaluating,
negotiating, entering into and arranging all such transactions and in connection with all other matters covered by paragraphs (a) (b) and (c) above, to use (subject only to insider dealing legislation) any information or opportunity,
howsoever acquired by it, to pursue its own interests exclusively, to refrain from disclosing such dealings, transactions or other matters or any information acquired in connection with them and to retain for its sole benefit all profits and
benefits derived from the dealings transactions or other matters. 

  
 95 

 Execution Copy 

 

 26.30 Resignation of the Security Trustee 

 

	(a)	The Security Trustee may resign and appoint one of its affiliates as successor by giving notice to the Borrower and each Secured Party. 

 

	(b)	Alternatively the Security Trustee may resign by giving notice to the other Parties in which case the Majority Lenders may appoint a successor Security Trustee. 

 

	(c)	If the Majority Lenders have not appointed a successor Security Trustee in accordance with paragraph (b) above within 30 days after the notice of resignation was given, the Security Trustee (after consultation with
the Agent) may appoint a successor Security Trustee. 

  

	(d)	The retiring Security Trustee (the “Retiring Security Trustee”) shall, at its own cost, make available to the successor Security Trustee such documents and records and provide such assistance as the successor
Security Trustee may reasonably request for the purposes of performing its functions as Security Trustee under the Finance Documents. 

  

	(e)	The Security Trustee’s resignation notice shall only take effect upon (i) the appointment of a successor and (ii) the transfer, by way of a document expressed as a deed, of all of the Security Property to
that successor. 

  

	(f)	Upon the appointment of a successor, the Retiring Security Trustee shall be discharged, by way of a document executed as a deed, from any further obligation in respect of the Finance Documents (other than its
obligations under paragraph (b) of Clause 26.49 (Winding up of trust) and under paragraph (d) above) but shall, in respect of any act or omission by it whilst it was the Security Trustee, remain entitled to the benefit of Clause 26
(The Security Trustee), Clause 26.5 (Deductions from receipts), Clause 26.16 (Lenders’ indemnity to the Security Trustee) and any other provisions of a Finance Document which are expressed to limit or exclude its liability in acting as Security
Trustee. Its successor and each of the other Parties shall have the same rights and obligations amongst themselves as they would have had if that successor had been an original Party. 

 

	(g)	The Majority Lenders may, by notice to the Security Trustee, require it to resign in accordance with paragraph (b) above. In this event, the Security Trustee shall resign in accordance with paragraph (b) above but
the cost referred to in paragraph (d) above shall be for the account of the Borrower. 

  

	(h)	The consent of the Borrower (or any other Obligor) is not required for an assignment or transfer of rights and/or obligations by the Security Trustee. 

26.31 Delegation 
  

	(a)	Each of the Security Trustee or any receiver may, at any time, delegate by power of attorney or otherwise to any person for any period, all or any of the rights, powers and discretions vested in it by any of the Finance
Documents. 

  

	(b)	That delegation may be made upon any terms and conditions (including the power to sub delegate) and subject to any restrictions that the Security Trustee or that receiver (as the case may be) may, in its discretion,
think fit in the interests of the Secured Parties and it shall not be bound to supervise, or be in any way responsible for any loss incurred by reason of any misconduct or default on the part of any such delegate or sub delegate. 

26.32 Additional Security Trustee 
  

	(a)	The Security Trustee may at any time appoint (and subsequently remove) any person to act as a separate trustee or as a co-trustee jointly with it: 

 

	(i)	if it considers that appointment to be in the interests of the Secured Parties; or 

  
 96 

 Execution Copy 

 

	(ii)	for the purposes of conforming to any legal requirements, restrictions or conditions which the Security Trustee deems to be relevant; or 

 

	(iii)	for obtaining or enforcing any judgment in any jurisdiction, 

 and the Security Trustee shall give prior notice
to the Borrower and the Agent of that appointment. 
  

	(b)	Any person so appointed shall have the rights, powers and discretions (not exceeding those conferred on the Security Trustee by this Agreement) and the duties and obligations that are conferred or imposed by the
instrument of appointment. 

  

	(c)	The remuneration that the Security Trustee may pay to that person, and any costs and expenses (together with any applicable VAT) incurred by that person in performing its functions pursuant to that appointment shall,
for the purposes of this Agreement, be treated as costs and expenses incurred by the Security Trustee. 

 27 CONDUCT OF BUSINESS BY THE
CREDITOR PARTIES 
 27.1 No provision of this Agreement will: 
  

	(a)	interfere with the right of any Creditor Party to arrange its affairs (Tax or otherwise) in whatever manner it thinks fit; 

  

	(b)	oblige any Creditor Party to investigate or claim any credit, relief, remission or repayment available to it or the extent, order and manner of any claim; or 

 

	(c)	oblige any Creditor Party to disclose any information relating to its affairs (Tax or otherwise) or any computations in respect of Tax. 

28 SHARING AMONG THE CREDITOR PARTIES 
 28.1 Payments
to Creditor Parties 
 If a Creditor Party (a “Recovering Creditor Party”) receives or recovers any amount from an Obligor other than in
accordance with Clause 28 (Sharing Among the Creditor Parties) and applies that amount to a payment due under the Finance Documents then: 
  

	(a)	the Recovering Creditor Party shall, within three (3) Business Days, notify details of the receipt or recovery to the Agent; 

  

	(b)	the Agent shall determine whether the receipt or recovery is in excess of the amount the Recovering Creditor Party would have been paid had the receipt or recovery been received or made by the Agent and distributed in
accordance with Clause 19 (Application of Sums Received) and Clause 29 (Payment Mechanics)), without taking account of any Tax which would be imposed on the Agent in relation to the receipt, recovery or distribution; and

  

	(c)	the Recovering Creditor Party shall, within three (3) Business Days of demand by the Agent, pay to the Agent an amount (the “Sharing Payment”) equal to such receipt or recovery less any amount which the
Agent determines may be retained by the Recovering Creditor Party as its share of any payment to be made, in accordance with Clause 19 (Application of Sums Received) and Clause 29 (Payment Mechanics). 

  
 97 

 Execution Copy 

 

 28.2 Redistribution of payments 

The Agent shall treat the Sharing Payment as if it had been paid by the relevant Obligor and distribute it between the Creditor Parties (other than the
Recovering Creditor Party) in accordance with Clause 19 (Application of Sums Received) and Clause 29 (Payment Mechanics). 
 28.3
Recovering Creditor Party’s rights 
  

	(a)	On a distribution by the Agent under Clause 28.2 (Redistribution of payments), the Recovering Creditor Party will, if possible under the relevant applicable laws, be subrogated to the rights of the Creditor
Parties which have shared in the redistribution. 

  

	(b)	If and to the extent that the Recovering Creditor Party is not able to rely on its rights under Clause 28.3(a), the relevant Obligor shall be liable to the Recovering Creditor Party for a debt equal to the Sharing
Payment which is immediately due and payable. 

 28.4 Reversal of redistribution 

If any part of the Sharing Payment received or recovered by a Recovering Creditor Party becomes repayable and is repaid by that Recovering Creditor Party,
then: 
  

	(a)	each Lender which has received a share of the relevant Sharing Payment pursuant to Clause 28.2 (Redistribution of payments) shall, upon request of the Agent, pay to the Agent for account of that Recovering
Creditor Party an amount equal to the appropriate part of its share of the Sharing Payment (together with an amount as is necessary to reimburse that Recovering Creditor Party for its proportion of any interest on the Sharing Payment which that
Recovering Creditor Party is required to pay); and 

  

	(b)	that Recovering Creditor Party’s rights of subrogation in respect of any reimbursement shall be cancelled and the relevant Obligor will be liable to the reimbursing Creditor Party for the amount so reimbursed.

 28.5 Exceptions 
  

	(a)	This Clause 28 (Sharing Among the Creditor Parties) shall not apply to the extent that the Recovering Creditor Party would not, after making any payment pursuant to this Clause, have a valid and enforceable claim
against the relevant Obligor. 

  

	(b)	A Recovering Creditor Party is not obliged to share with any other Creditor Party any amount which the Recovering Creditor Party has received or recovered as a result of taking legal or arbitration proceedings, if:

  

	(i)	it notified that other Creditor Party of the legal or arbitration proceedings; and 

  

	(ii)	that other Creditor Party had an opportunity to participate in those legal or arbitration proceedings but did not do so as soon as reasonably practicable having received notice and did not take separate legal or
arbitration proceedings. 

  

	29	PAYMENT MECHANICS 

 29.1 Payments to the Agent 

 

	(a)	On each date on which an Obligor or a Lender is required to make a payment under a Finance Document, that Obligor or Lender shall make the same available to the Agent (unless a contrary indication appears in a Finance
Document) for value on the due date at the time and in such funds specified by the Agent as being customary at the time for settlement of transactions in the relevant currency in the place of payment. 

  
 98 

 Execution Copy 

 

	(b)	Payment shall be made to such account in the principal financial centre of the country of that currency (or, in relation to Euro, in a principal financial centre in a Participating Member State or London) with such bank
as the Agent specifies. 

  

	(c)	Payment shall be made before 11.00 a.m. New York time or 11.00 a.m. Paris time (in the case of a payment in Euro). 

  

	(d)	For each payment by the Borrower, it shall notify the Agent on the third Business Day prior to the due date for payment that it will issue to its bank (which shall be named in such notification) to make the payment.

 29.2 Distributions by the Agent 
 Each
payment received by the Agent under the Finance Documents for another Party shall, subject to Clause 29.3 (Distributions to an Obligor), Clause 29.4 (Clawback) be made available by the Agent as soon as practicable after receipt to the
Party entitled to receive payment in accordance with this Agreement (in the case of a Lender, for the account of its Facility Office), to such account as that Party may notify to the Agent by not less than five (5) Business Days’ notice
with a bank in the principal financial centre of the country of that currency (or, in relation to Euro, in the principal financial centre of a Participating Member State or London). 

29.3 Distributions to an Obligor 
 The Agent may in
accordance with Clause 22 (Set-Off) apply any amount received by it for that Obligor in or towards payment (on the date and in the currency and funds of receipt) of any amount due from that Obligor under the Finance Documents or in or towards
purchase of any amount of any currency to be so applied. 
 29.4 Clawback 
  

	(a)	Where a sum is to be paid to the Agent under the Finance Documents for another Party, the Agent is not obliged to pay that sum to that other Party (or to enter into or perform any related exchange contract) until it has
been able to establish to its satisfaction that it has actually received that sum. 

  

	(b)	If the Agent pays an amount to another Party and it proves to be the case that the Agent had not actually received that amount, then the Party to whom that amount (or the proceeds of any related exchange contract) was
paid by the Agent shall on demand refund the same to the Agent together with interest on that amount from the date of payment to the date of receipt by the Agent, calculated by the Agent to reflect its cost of funds. 

29.5 No set-off by Obligors 
 All payments to be made by
an Obligor under the Finance Documents shall be calculated and be made without (and free and clear of any deduction for) set-off or counterclaim. 
 29.6
Business Days 
  

	(a)	Any payment which is due to be made on a day that is not a Business Day shall be made on the next Business Day in the same calendar month (if there is one) or the preceding Business Day (if there is not).

  

	(b)	During any extension of the due date for payment of any principal or unpaid sum under this Agreement interest is payable on the principal or unpaid sum at the rate payable on the original due date. 

  
 99 

 Execution Copy 

 

 29.7 Currency of account 
  

	(a)	Subject to Clauses 29.7(b) and 29.7(c) Dollars is the currency of account and payment for any sum from an Obligor under any Finance Document. 

 

	(b)	Each payment in respect of costs, expenses or Taxes shall be made in the currency in which the costs, expenses or taxes are incurred. 

 

	(c)	Any amount expressed to be payable in a currency other than Dollars shall be paid in that other currency. 

29.8 Change of currency 
  

	(a)	Unless otherwise prohibited by law, if more than one currency or currency unit are at the same time recognised by the central bank of any country as the lawful currency of that country, then: 

 

	(i)	any reference in the Finance Documents to, and any obligations arising under the Finance Documents in, the currency of that country shall be translated into, or paid in, the currency or currency unit of that country
designated by the Agent (after consultation with the Lenders and the Borrower); and 

  

	(ii)	any translation from one currency or currency unit to another shall be at the official rate of exchange recognised by the central bank for the conversion of that currency or currency unit into the other, rounded up or
down by the Agent (acting reasonably). 

  

	(b)	If a change in any currency of a country occurs, this Agreement will, to the extent the Agent (acting reasonably and after consultation with the Lenders and the Borrower) specifies to be necessary, be amended to comply
with any generally accepted conventions and market practice in the Relevant Interbank Market and otherwise to reflect the change in currency. 

29.9 Distributions under the Interest Make-Up Agreement 

Each payment received by the Agent under the Interest Make-Up Agreement for a Lender shall be made available by the Agent as soon as practicable after receipt
to the Lender entitled to receive such payment in accordance with this Agreement (for the account of its Facility Office), to such account as that Lender may notify to the Agent by not less than five (5) Business Days’ notice with a bank
in the principal financial centre of the country of that currency (or, in relation to Euro, in the principal financial centre of a Participating Member State or London). 

30 VARIATIONS AND WAIVERS 
 30.1 Variations, waivers
etc. by Majority Lenders 
 Subject to Clause 30.2 and Clause 30.4, a document shall be effective to vary, waive, amend, suspend or limit any provision
of a Finance Document, or any Creditor Party’s rights or remedies under such a provision or the general law, only if the document is signed, or specifically agreed to by fax, by the Borrower, by the Agent on behalf of the Majority Lenders, by
the Agent and the Security Trustee in their own rights, and, if the document relates to a Finance Document to which an Obligor is party, by an Obligor (provided that no amendment or variation may be made to this Agreement or any other Finance
Document without the consent of the Italian Authorities); provided, further, that no amendment or variation may be made before the date falling ten Business Days after the terms of that amendment or variation have been notified by the Agent to the
Lenders, unless each Lender is a FATCA Protected Lender. The Agent shall notify the Lenders reasonably promptly of any amendments or variations proposed by the Borrower. 

  
 100 

 Execution Copy 

 

 30.2 Variations, waivers etc. requiring agreement of all Lenders 

However, as regards the following, Clause 30.1 applies as if the words “by the Agent on behalf of the Majority Lenders” were replaced by the words
“by or on behalf of every Lender”: 
  

	(a)	a reduction in the Margin; 

  

	(b)	a postponement to the date for, or a reduction in the amount of, any payment of principal, interest, fees, commission or other sum payable under this Agreement; 

 

	(c)	an increase in or extension of any Lender’s Commitment or any requirement that a cancellation of Commitments reduces the Commitments rateably under the Loan; 

 

	(d)	a change to the definition of “Majority Lenders”; 

  

	(e)	a change to Clause 2 (Facility), Clause 6 (Interest), Clause 23 (Changes to the Lenders) or this Clause 30 (Variations and Waivers); 

 

	(f)	any release of, or material variation to, a Security Interest, guarantee, indemnity or subordination arrangement set out in a Finance Document; and 

 

	(g)	any other change or matter as regards which this Agreement or another Finance Document expressly provides that each Lender’s consent is required. 

30.3 Exclusion of other or implied variations 
 Except for
a document which satisfies the requirements of Clauses 30.1 and 30.2, no document, and no act, course of conduct, failure or neglect to act, delay or acquiescence on the part of the Creditor Parties or any of them (or any person acting on behalf of
any of them) shall result in the Creditor Parties or any of them (or any person acting on behalf of any of them) being taken to have varied, waived, suspended or limited, or being precluded (permanently or temporarily) from enforcing, relying on or
exercising: 
  

	(a)	a provision of this Agreement or another Finance Document; or 

  

	(b)	an Event of Default; or 

  

	(c)	a breach by the Borrower or an Obligor of an obligation under a Finance Document or the general law; or 

  

	(d)	any right or remedy conferred by any Finance Document or by the general law, 

 and there shall not be implied
into any Finance Document any term or condition requiring any such provision to be enforced, or such right or remedy to be exercised, within a certain or reasonable time. 

30.4 Other exceptions – FATCA 
  

	(a)	If the Agent or a Lender reasonably believes that an amendment or waiver may constitute a “material modification” for the purposes of FATCA that may result (directly or indirectly) in a Party being required to
make a FATCA Deduction and the Agent or that Lender (as the case may be) notifies the Borrower and the Agent accordingly, that amendment or waiver may, subject to paragraph (b) below, not be effected without the consent of the Agent or that
Lender (as the case may be). 

  

	(b)	The consent of a Lender shall not be required pursuant to paragraph (a) above if that Lender is a FATCA Protected Lender. 

  
 101 

 Execution Copy 

 

 31 NOTICES 

31.1 General 
 Unless otherwise specifically provided, any
notice under or in connection with any Finance Document shall be given by letter or fax; and references in the Finance Documents to written notices, notices in writing and notices signed by particular persons shall be construed accordingly. 

31.2 Addresses for communications 
 A notice shall be
sent: 
  

					
	(a)	  	to the Borrower:	  	8300 NW 33rd Street #308
		  		  	Miami FL33122, USA
			
		  		  	Fax No: (00) 1 305 514 2297
			
	(b)	  		  	to a Lender: At the address below its name in Schedule 1 or (as the case may require) in the relevant Transfer Certificate.
			
	(c)	  	to the Agent or the SACE	  	9 quai du Président Paul DoumerAgent:
		  		  	92920 Paris La Défense Cedex
		  		  	Paris
			
		  		  	Fax No: (33) 1 41 89 29 87
		  		  	Attn: Shipping Group - Mr Jerome Leblond
			
		  		  	and
			
		  		  	Fax No. (33) 1 41 89 19 34
		  		  	Attn: Shipping Middle Office – Ms Sylvie Godet-Couery

 or to such other address as the relevant party may notify the Agent or, if the relevant party is the Agent, the Borrower and
the Lenders. 
 31.3 Effective date of notices 
 Subject
to Clauses 31.4 (Service outside business hours) and 31.5 (Electronic communication): 
  

	(a)	a notice which is delivered personally or posted shall be deemed to be served, and shall take effect, at the time when it is delivered; 

 

	(b)	a notice which is sent by fax shall be deemed to be served, and shall take effect, 2 hours after its transmission is completed. 

31.4 Service outside business hours 
 However, if under
Clause 31.3 (Effective date of notices) a notice would be deemed to be served: 
  

	(a)	on a day which is not a business day in the place of receipt; or 

  

	(b)	on such a business day, but after 6 p.m. local time; 

 the notice shall (subject to 31.5 (Electronic
communication) be deemed to be served, and shall take effect, at 9 a.m. on the next day which is such a business day. 

  
 102 

 Execution Copy 

 

 31.5 Electronic communication 

 

	(a)	Any communication to be made between any two Parties under or in connection with the Finance Documents may be made by electronic mail or other electronic means, to the extent that those two Parties agree that, unless
and until notified to the contrary, this is to be an accepted form of communication and if those two Parties: 

  

	(i)	notify each other in writing of their electronic mail address and/or any other information required to enable the sending and receipt of information by that means; and 

 

	(ii)	notify each other of any change to their address or any other such information supplied by them by not less than five Business Days’ notice. 

 

	(b)	Any electronic communication made between those two Parties will be effective only when actually received in readable form and in the case of any electronic communication made by a Party to the Agent only if it is
addressed in such a manner as the Agent shall specify for this purpose. 

  

	(c)	Any electronic communication which becomes effective, in accordance with paragraph (b) above, after 5.00 p.m. in the place of receipt shall be deemed only to become effective on the following day.

 31.6 Illegible notices 
 Clauses 31.3
(Effective date of notices) and 31.4 (Service outside business hours) do not apply if the recipient of a notice notifies the sender within 1 hour after the time at which the notice would otherwise be deemed to be served that the notice
has been received in a form which is illegible in a material respect. 
 31.7 Valid notices 

A notice under or in connection with a Finance Document shall not be invalid by reason that its contents or the manner of serving it do not comply with the
requirements of this Agreement or, where appropriate, any other Finance Document under which it is served if: 
  

	(a)	the failure to serve it in accordance with the requirements of this Agreement or other Finance Document, as the case may be, has not caused any party to suffer any significant loss or prejudice; or 

 

	(b)	in the case of incorrect and/or incomplete contents, it should have been reasonably clear to the party on which the notice was served what the correct or missing particulars should have been. 

31.8 English language 
 Any notice under or in connection
with a Finance Document shall be in English. 
 31.9 Meaning of “notice” 

In this Clause 31 (Notices), “notice” includes any demand, consent, authorisation, approval, instruction, waiver or other
communication. 

  
 103 

 Execution Copy 

 

 32 CONFIDENTIALITY 

32.1 Confidential Information 
 Each Creditor Party agrees
to keep all Confidential Information confidential and not to disclose it to anyone, save to the extent permitted by Clause 32.2 (Disclosure of Confidential Information) and to ensure that all Confidential Information is protected with
security measures and a degree of care that would apply to its own confidential information. 
 32.2 Disclosure of Confidential Information 

Any Creditor Party may disclose: 
  

	(a)	to the Italian Authorities, any of its Affiliates and any of its or their officers, directors, employees, professional advisers, auditors, partners and Representatives such Confidential Information as that Creditor
Party shall consider appropriate if any person to whom the Confidential Information is to be given pursuant to this paragraph (a) is informed in writing of its confidential nature and that some or all of such Confidential Information may be
price-sensitive information except that there shall be no such requirement to so inform if the recipient is subject to professional obligations to maintain the confidentiality of the information or is otherwise bound by requirements of
confidentiality in relation to the Confidential Information; 

  

	(b)	to any person: 

  

	(i)	to (or through) whom it assigns or transfers (or may potentially assign or transfer) all or any of its rights and/or obligations under one or more Finance Documents and to any of that person’s Affiliates,
Representatives and professional advisers; 

  

	(ii)	with (or through) whom it enters into (or may potentially enter into), whether directly or indirectly, any sub-participation in relation to, or any other transaction under which payments are to be made or may be made by
reference to, one or more Finance Documents and/or one or more Obligors and to any of that person’s Affiliates, Representatives and professional advisers; 

  

	(iii)	appointed by any Creditor Party or by a person to whom paragraph (b)(i) or (ii) above applies to receive communications, notices, information or documents delivered pursuant to the Finance Documents on its behalf;

  

	(iV)	who invests in or otherwise finances (or may potentially invest in or otherwise finance), directly or indirectly, any transaction referred to in paragraph (b)(i) or (b)(ii) above; 

 

	(v)	to whom information is required or requested to be disclosed by any court of competent jurisdiction or any governmental, banking, taxation or other regulatory authority or similar body, the rules of any relevant stock
exchange or pursuant to any applicable law or regulation; 

  

	(vi)	to whom information is required to be disclosed in connection with, and for the purposes of, any litigation, arbitrations, administrative or other investigations, proceedings or disputes; 

 

	(vii)	who is a Party, a member of the Group or any related entity of an Obligor; 

  

	(viii)	as a result of the registration of any Finance Document as contemplated by any Finance Document or any legal opinion obtained in connection with any Finance Document; or 

 

	(ix)	with the consent of Prestige Holdings; or 

  

	(x)	any employee, officer, director or Representative of any Italian Authorities to whom information is required to be disclosed in the course of such person’s employment or duties; 

 

	(xi)	to whom or for whose benefit that Creditor Party charges, assigns or otherwise creates a Security Interest (or may do so) pursuant to Clause 23.16 (Security over Lenders’ rights). 

  
 104 

 Execution Copy 

 

 in each case, such Confidential Information as that Creditor Party shall consider appropriate if: 

 

	(A)	in relation to paragraphs (b)(i), (b)(ii) and (b)(iii) above, the person to whom the Confidential Information is to be given has entered into a Confidentiality Undertaking except that there shall be no requirement for a
Confidentiality Undertaking if the recipient is a professional adviser and is subject to professional obligations to maintain the confidentiality of the Confidential Information; 

 

	(B)	in relation to paragraph (b)(iv) above, the person to whom the Confidential Information is to be given has entered into a Confidentiality Undertaking or is otherwise bound by requirements of confidentiality in relation
to the Confidential Information they receive and is informed that some or all of such Confidential Information may be price-sensitive information; 

  

	(C)	in relation to paragraphs (b)(v), (b)(vi) and (b)(xi) above, the person to whom the Confidential Information is to be given is informed of its confidential nature and that some or all of such Confidential Information
may be price-sensitive information except that there shall be no requirement to so inform if, in the opinion of that Creditor Party, it is not practicable so to do in the circumstances; 

 

	(c)	to any person appointed by that Creditor Party or by a person to whom paragraph (b)(i) or (b)(ii) above applies to provide administration or settlement services in respect of one or more of the Finance Documents
including without limitation, in relation to the trading of participations in respect of the Finance Documents, such Confidential Information as may be required to be disclosed to enable such service provider to provide any of the services referred
to in this paragraph (c) if the service provider to whom the Confidential Information is to be given has entered in to a confidentiality agreement substantially in the form of the LMA Master Confidentiality Undertaking for Use With
Administration/Settlement Service Providers or such other form of confidentiality undertaking agreed between the Borrower and the relevant Creditor Party; 

  

	(d)	to any rating agency (including its professional advisers) such Confidential Information as may be required to be disclosed to enable such rating agency to carry out its normal rating activities in relation to the
Finance Documents and/or the Obligors if the rating agency to whom the Confidential Information is to be given is informed of its confidential nature and that some or all of such Confidential Information may be price-sensitive information.

 32.3 Entire agreement 
 This Clause 32
(Confidentiality) constitutes the entire agreement between the Parties in relation to the obligations of the Creditor Parties under the Finance Documents regarding Confidential Information and supersedes any previous agreement, whether
express or implied, regarding Confidential Information. 
 32.4 Inside information 

Each of the Creditor Parties acknowledges that some or all of the Confidential Information is or may be price-sensitive information and that the use of such
information may be regulated or prohibited by applicable legislation including securities law relating to insider dealing and market abuse and each of the Creditor Parties undertakes not to use any Confidential Information for any unlawful purpose.

  
 105 

 Execution Copy 

 

 32.5 Notification of disclosure 

Each of the Creditor Parties agrees (to the extent permitted by law and regulation) to inform the Borrower: 

 

	(a)	of the circumstances of any disclosure of Confidential Information made pursuant to paragraph (b)(v) of Clause 32.2 (Disclosure of Confidential Information) except where such disclosure is made to any of the persons
referred to in that paragraph during the ordinary course of its supervisory or regulatory function; and 

  

	(b)	upon becoming aware that Confidential Information has been disclosed in breach of this Clause 32 (Confidentiality). 

32.6 Continuing obligations 
 The obligations in this 32
(Confidentiality) are continuing and, in particular, shall survive and remain binding on each Creditor Party for a period of 12 months from the earlier of: 
  

	(a)	the date on which all amounts payable by the Obligors under or in connection with this Agreement have been paid in full and all Commitments have been cancelled or otherwise cease to be available; and 

 

	(b)	the date on which such Creditor Party otherwise ceases to be a Creditor Party. 

 33 SUPPLEMENTAL 

33.1 Rights cumulative, non-exclusive 
 The rights and
remedies which the Finance Documents give to each Secured Party are: 
  

	(a)	cumulative; 

  

	(b)	may be exercised as often as appears expedient; and 

  

	(c)	shall not, unless a Finance Document explicitly and specifically states so, be taken to exclude or limit any right or remedy conferred by any law. 

33.2 Severability of provisions 
 If any provision of a
Finance Document is or subsequently becomes void, unenforceable or illegal, that shall not affect the validity, enforceability or legality of the other provisions of that Finance Document or of the provisions of any other Finance Document. 

33.3 Counterparts 
 A Finance Document may be executed in
any number of counterparts. 
 33.4 Third party rights 

A person who is not a party to this Agreement has no right under the Contracts (Rights of Third Parties) Act 1999 to enforce or to enjoy the benefit of any
term of this Agreement. 
 33.5 No waiver 
 No failure
or delay on the part of a Secured Party in exercising any right, power or privilege hereunder shall operate as a waiver thereof; nor shall any single or partial exercise thereof preclude any other or further exercise thereof by the Secured Parties
or the exercise by the Secured Parties of any other right, power or privilege. The rights and remedies of the Secured Parties herein provided are cumulative and not exclusive of any rights or remedies provided by law. 

  
 106 

 Execution Copy 

 

 33.6 Writing required 

This Agreement shall not be capable of being modified otherwise than by an express modification in writing signed by the Borrower, the Agent and the Lenders.

 34 GOVERNING LAW 
 34.1 Law 

This Agreement and any non-contractual obligations arising out of or in connection with it are governed by and construed in accordance with English law. 

35 ENFORCEMENT 
 35.1 Jurisdiction of English Courts

 The courts of England have exclusive jurisdiction to settle any Dispute arising out of or in connection with this Agreement (including a dispute
regarding the existence, validity or termination of this Agreement) (a “Dispute”). Each Party agrees that the courts of England are the most appropriate and convenient courts to settle Disputes and accordingly no Party will argue to
the contrary. 
 This Clause 35.1 (Jurisdiction of English Courts) is for the benefit of the Creditor Parties only. As a result, no Creditor Party
shall be prevented from taking proceedings relating to a Dispute in any other courts with jurisdiction. To the extent allowed by law, any Creditor Party may take concurrent proceedings in any number of jurisdictions. 

35.2 Service of process 
 Without prejudice to any other
mode of service allowed under any relevant law, the Borrower: 
  

	(a)	irrevocably appoints EC3 Services Limited of The St Botolph Building, 138 Houndsditch, London EC3A 7AR, United Kingdom, as its agent for service of process in relation to any proceedings before the English courts in
connection with any Finance Document; and 

  

	(b)	agrees that failure by a process agent to notify the Borrower of the process will not invalidate the proceedings concerned. 

  

	(c)	If any person appointed as an agent for service of process is unable for any reason to act as agent for service of process, the Borrower (on behalf of all the Obligors) must immediately (and in any event within 15 days
of such event taking place) appoint another agent on terms acceptable to the Agent. Failing this, the Agent may appoint another agent for this purpose. 

THIS AGREEMENT has been entered into on the date stated at the beginning of this Agreement. 

  
 107 

 Execution Copy 

 

 Schedule 1 

LENDERS AND COMMITMENTS 
  

							
	Lender	  	Facility Office	  	Commitment
(%)	 
			
	 Crédit Agricole Corporate and Investment Bank
	  	 9 quai du Président Paul Doumer
 92920
Paris La Défense Cedex
 France
	  	 	[*	]% 
			
	 HSBC Bank plc
	  	 Level 18, 8 Canada Square
 London E14 5HQ

United Kingdom
	  	 	[*	]% 
			
	 Société Générale
	  	 29 Boulevard Haussmann
 75009 Paris

France
	  	 	[*	]% 
			
	 KFW IPEX-Bank GmbH
	  	 KFW IPEX-Bank GmbH
 Palmengartenstr. 5-9

60325 Frankfurt
 Germany
	  	 	[*	]% 

  
 108 

 Execution Copy 

 

 Schedule 2 

FORM OF DRAWDOWN NOTICE 
 To:
[Crédit Agricole Corporate and Investment Bank] 
 Attention: [Loans Administration] 

[—] 

DRAWDOWN NOTICE 
 1 We refer to the loan
agreement (the “Loan Agreement”) dated [—] 2013 and made between ourselves, as Borrower, the Lenders and Joint Mandated Lead Arrangers referred to therein, and yourselves as Agent
in connection with a facility of the Dollar Equivalent of up to EUR[—]. Terms defined in the Loan Agreement have their defined meanings when used in this Drawdown Notice. 

2 We request to borrow as follows:- 
  

	(a)	Amount: 

  

	(i)	US$[—] in respect of the payment of the Eligible Amount of the Final Contract Price to be paid to the Builder to the account specified in paragraph (d) below;

  

	(ii)	US$[—] in respect of the First Instalment of the SACE Premium to be reimbursed to the Borrower to the account specified in paragraph (d) below; 

 

	(iii)	US$[—] in respect of the Second Instalment of the SACE Premium to be paid, in accordance with paragraph (d) below to SACE. 

 

	(b)	Drawdown Date: [—]; 

  

	(c)	[Duration of the first Interest Period shall be [—] months;] 

  

	(d)	Payment instructions: [account details to be completed in respect of (i), (ii) and (iii) above]. 

3 We represent and warrant that: 
  

	(a)	the representations and warranties in Clauses 11.2 (Continuing representations and warranties) and 11.3 (Representations on the Delivery Date) of the Loan Agreement would remain true and not misleading if
repeated on the date of this notice with reference to the circumstances now existing; 

  

	(b)	no Event of Default has occurred or will result from the borrowing of the Loan. 

 4 This notice cannot be
revoked without the prior consent of the Agent. 
 5 We authorise you to deduct the commitment fee accrued and unpaid referred to in Clause 9.1(b) from the
amount of the Loan drawn pursuant to paragraph 2(a)(ii) above. 
 [Name of Signatory] 

Director 
 for and on behalf of

 EXPLORER NEW BUILD, LLC 

  
 109 

 Execution Copy 

 

 Schedule 3 

DOCUMENTS TO BE PRODUCED BY THE BUILDER TO THE AGENT ON DELIVERY 

1 Certified copies of the commercial invoice, evidencing payment by the Borrower and receipt by the Builder of the instalments already paid pursuant to the
Shipbuilding Contract and the Final Contract Price, duly executed by the Builder in favour of the Borrower and countersigned by the Borrower. 
 2 Certified
copy of bank statements evidencing receipt by the Builder of the first, second, third and fourth instalments of the Initial Contract Price (as described in Recital (B)). 

3 Certified Copy of the Protocol of Delivery and Acceptance, duly executed by the Builder and the Borrower. 

4 Certified Copy of the declaration of warranty, duly executed by the Builder confirming that the Ship is delivered to the Borrower free and clear of all
encumbrances whatsoever. 
 5 Certified Copy of the commercial invoice(s) corresponding to the Change Orders (if any) or any other similar document issued
by the Builder stating the Change Order Amount and evidencing the payment by the Borrower and receipt by the Builder of the amounts not being financed by the Loan and of all final amounts due at delivery, duly executed by the Builder in favour of
the Borrower and countersigned by the Borrower. 
 6 Certified copy of (i) the builder’s certificate duly executed by the Builder and (ii) a
Qualifying Certificate duly signed by the Builder specifying the origin of the exported goods and in which there are declared all the amounts transferred abroad for any reason regarding the performance of the Shipbuilding Contract. 

7 Certified copy of the acknowledgement of the notice of assignment of the Borrower’s rights under the post-delivery warranty given by the Builder under
the Shipbuilding Contract pursuant to the Post-Delivery Assignment. 
 8 Certified Copy of the power of attorney pursuant to which the authorised signatory
of the Builder signed the documents referred to in this 0 and a specimen of his signature. 
 9 Certified Copy of the Exporter’s Declaration to SIMEST
duly executed by the Builder and delivered to SIMEST (where the Fixed Interest Rate has been selected). 

  
 110 

 Execution Copy 

 

 Schedule 4 

FORM OF TRANSFER CERTIFICATE 
 The
Transferor and the Transferee accept exclusive responsibility for ensuring that this Certificate and the transaction to which it relates comply with all legal and regulatory requirements applicable to them respectively. 

 

	To:	[Name of Agent] for itself and for and on behalf of the Borrower, any other Obligor, the Security Trustee and each Lender, as defined in the Loan Agreement referred to below. 

[—] 

1 This Certificate relates to a Loan Agreement (the “Loan Agreement”) dated [—] 2013 and
made between (1) Explorer New Build, LLC (the “Borrower”), (2) the banks and financial institutions named therein as lenders (3) Crédit Agricole Corporate and Investment Bank as Agent and (4) Crédit
Agricole Corporate and Investment Bank as Security Trustee for a loan facility of up to US$440,321,648.78. 
 2 In this Certificate, terms defined in the
Loan Agreement shall, unless the contrary intention appears, have the same meanings and: 
 “Relevant Parties” means the Agent, the
Borrower, any other Obligor, the Security Trustee and each Lender. 
 “Transferor” means [full name] of [facility office]. 

“Transferee” means [full name] of [facility office]. 

3 The effective date of this Certificate is [—] Provided that this Certificate shall not come into
effect unless it is signed by the Agent on or before that date. 
 4 The Transferor assigns to the Transferee absolutely all rights and interests (present,
future or contingent) which the Transferor has as Lender under or by virtue of the Loan Agreement and every other Finance Document in relation to [—] per cent. of its Contribution, which percentage
represents $[—]. 
 5 By virtue of this Certificate and Clause 23 (Changes to the Lenders) of the
Loan Agreement, the Transferor is discharged [entirely from its Commitment which amounts to $[—]] [from [—] per cent. of its Commitment, which
percentage represents $[—]] and the Transferee acquires a Commitment of $[—].] 

6 The Transferee undertakes with the Transferor and each of the Relevant Parties that the Transferee will observe and perform all the obligations under the
Finance Documents which Clause 23 (Changes to the Lenders) of the Loan Agreement provides will become binding on it upon this Certificate taking effect. 

7 The Agent, at the request of the Transferee (which request is hereby made) accepts, for the Agent itself and for and on behalf of every other Relevant
Party, this Certificate as a Transfer Certificate taking effect in accordance with Clause 23 (Changes to the Lenders) of the Loan Agreement. 

  
 111 

 Execution Copy 

 

 8 The Transferor: 

(a) warrants to the Transferee and each Relevant Party that: 
  

	(i)	the Transferor has full capacity to enter into this transaction and has taken all corporate action and obtained all consents which are in connection with this transaction; and 

 

	(ii)	this Certificate is valid and binding as regards the Transferor; 

  

	(b)	warrants to the Transferee that the Transferor is absolutely entitled, free of encumbrances, to all the rights and interests covered by the assignment in paragraph 4 above; and 

 

	(c)	undertakes with the Transferee that the Transferor will, at its own expense, execute any documents which the Transferee reasonably requests for perfecting in any relevant jurisdiction the Transferee’s title under
this Certificate or for a similar purpose. 

 9 The Transferee: 
  

	(a)	confirms that it has received a copy of the Loan Agreement and each of the other Finance Documents; 

  

	(b)	agrees that it will have no rights of recourse on any ground against either the Transferor, the Agent, the Security Trustee or any Lender in the event that: 

 

	(i)	any of the Finance Documents prove to be invalid or ineffective; 

  

	(ii)	the Borrower or any Obligor fails to observe or perform its obligations, or to discharge its liabilities, under any of the Finance Documents; 

 

	(iii)	it proves impossible to realise any asset covered by a Security Interest created by a Finance Document, or the proceeds of such assets are insufficient to discharge the liabilities of the Borrower or other Obligors
under the Finance Documents; 

  

	(c)	agrees that it will have no rights of recourse on any ground against the Agent, the Security Trustee or any Lender in the event that this Certificate proves to be invalid or ineffective; 

 

	(d)	warrants to the Transferor and each Relevant Party that: 

  

	(i)	it has full capacity to enter into this transaction and has taken all corporate action and obtained all consents which it needs to take or obtain in connection with this transaction; and 

 

	(ii)	this Certificate is valid and binding as regards the Transferee; and 

  

	(e)	confirms the accuracy of the administrative details set out below regarding the Transferee. 

  

	10	The Transferor and the Transferee each undertake with the Agent and the Security Trustee severally, on demand, fully to indemnify the Agent and/or the Security Trustee in respect of any claim, proceeding, liability or
expense (including all legal expenses) which they or either of them may incur in connection with this Certificate or any matter arising out of it, except such as are shown to have been mainly and directly caused by the gross and culpable negligence
or dishonesty of the Agent’s or the Security Trustee’s own officers or employees. 

  

	11	The Transferee shall repay to the Transferor on demand so much of any sum paid by the 

  
 112 

 Execution Copy 

 

					
	[Name of Transferor]	 		 	[Name of Transferee]
			
	By:	 		 	By:
			
	Date:	 		 	Date:

 Agent 
 Signed for itself and
for and on behalf of itself 
 as Agent and for every other Relevant Party 
  

	
	[Name of Agent]
	
	 By:

	
	 Date:

  
 113 

 Execution Copy 

 

 Administrative Details of Transferee 

Name of Transferee: 
 Facility Office: 

Contact Person 
 (Loan Administration Department): 

Telephone: 
 Fax: 

Contact Person 
 (Credit Administration Department): 

Telephone: 
 Fax: 

Account for payments: 
  

	Note:	This Transfer Certificate alone may not be sufficient to transfer a proportionate share of the Transferor’s interest in the security constituted by the Finance Documents in the Transferor’s or
Transferee’s jurisdiction. It is the responsibility of each Lender to ascertain whether any other documents are required for this purpose. 

  
 114 

 Execution Copy 

 

 Schedule 5 

QUALIFYING CERTIFICATE 
 To: Credit
Agricole Corporate and Investment Bank as Agent (the “Agent”) 
 cc: Explorer New Build, LLC as Borrower 

From: Fincantieri Cantieri Navali Italiani S.p.A (the “Builder”) 

Date: 
 Dear Sirs, 

 

	1	We refer to the up to SACE backed term facility agreement dated [—] 2013 (the “Facility Agreement”) and entered into between, among others, the Agent,
the Borrower and the financial institutions named therein as Lenders. Terms defined in the Facility Agreement shall have the same meaning when used herein. 

  

	2	This is a Qualifying Certificate. 

  

	3	This Qualifying Certificate relates to the Drawdown Notice dated [—]. 

  

	4	We attach hereto the following documents in respect of the Ship to be delivered on the Drawdown Date under the Shipbuilding Contract: 

 

	(a)	a copy (certified as a true copy by the Builder) of the invoice(s) from the Builder in respect of the Ship intended to be refinanced by the proposed Loan; 

 

	(b)	the Builder’s Certificate and Declaration of Warranty (as each is defined in the Shipbuilding Contract); 

  

	(c)	the protocol of delivery and acceptance issued under the Shipbuilding Contract; and 

  

	(d)	a duly executed Exporter Declaration. 

  

	5	We hereby certify that the cumulative total amount invoiced by us pursuant to the Shipbuilding Contract and to be paid by the Borrower as direct payment is as follows: EUR
[—] corresponding to not less than 20% of the Final Contract Price of the Ship. 

  

	6	We certify that, to the best of our knowledge and belief, the SACE Insurance Policy will apply to the Loan requested in the Drawdown Notice referred to above when it is made. 

 

	7	We hereby warrant that: 

  

	(a)	the amount claimed does not include any sum in respect of any matter currently the subject of arbitration or other proceeding nor to the best of our knowledge and belief will it be the subject of arbitration or other
proceeding; 

  

	(b)	the Shipbuilding Contract has not been terminated, suspended or amended and to the best of our knowledge and belief no action is proceeding which might lead to the termination or suspension thereof; 

 

	(c)	all documents supplied by us in support of this Qualifying Certificate are in all material respect in conformity with the Shipbuilding Contract and SACE’s requirements; you may rely on the accuracy and completeness
of all information and documents contained in or supplied with this Qualifying Certificate or delivered pursuant thereto; 

  
 115 

 Execution Copy 

 

	(i)	the goods incorporated in and used for the construction of the Ship have the origin set out in the table below and complies with the requirements of the SACE Insurance Policy; and 

 

					
	Origin of the goods incorporated in the Ship	  	Value in percentage of the total Contract Price of
the Ship	  	Relevant portion of the Contract Price of the
Ship
			
	Italian goods	  	[—]%	  	EUR [—]
			
	Other EU goods	  	[—]%	  	EUR [—]
			
	Extra EU goods (if any)	  	[—]%	  	EUR [—]
			
		  	Total Contract Price of the Ship (in percentage) = 100%	  	Total Contract Price of the Ship = EUR [—]

  

	(ii)	the aggregate amounts transferred abroad (importi trasferiti all’estero) up to the date hereof and to be transferred abroad following the Drawdown Date for any reason connected to the performance of the
Shipbuilding Contract, are equal to EUR [—]. 

  

	
	Yours faithfully,
	
	Fincantieri Cantieri Navali Italiani S.p.A
	For and on behalf of the Builder
	(the Authorised Signatory of the Builder)

  
 116 

 Execution Copy 

 

 EXECUTION PAGES 

 

			
	BORROWER	  	
		
	SIGNED by	  	)
		  	)
	for and on behalf of	  	)
	EXPLORER NEW BUILD, LLC	  	)
	in the presence of:	  	)
		
	LENDERS	  	
		
	SIGNED by	  	)
		  	)
	for and on behalf of	  	)
	CREDIT AGRICOLE CORPORATE	  	)
	AND INVESTMENT BANK	  	)
	in the presence of:	  	)
		
	SIGNED by	  	)
		  	)
	for and on behalf of	  	)
	SOCIÉTÉ GÉNÉRALE	  	)
	in the presence of:	  	)
		
	SIGNED by	  	)
		  	)
	for and on behalf of	  	)
	KFW IPEX BANK GMBH	  	)
	in the presence of:	  	)

  
 117 

 Execution Copy 

 

			
	SIGNED by	  	)
		  	)
	for and on behalf of	  	)
	HSBC BANK PLC	  	)
	in the presence of:	  	)
		
	AGENT	  	
		
	SIGNED by	  	)
		  	)
	for and on behalf of	  	)
	CRÉDIT AGRICOLE CORPORATE	  	)
	AND INVESTMENT BANK	  	)
	in the presence of:	  	)
		
	SECURITY TRUSTEE	  	
		
	SIGNED by	  	)
		  	)
	for and on behalf of	  	)
	CRÉDIT AGRICOLE CORPORATE	  	)
	AND INVESTMENT BANK	  	)
	in the presence of:	  	)
		
	SACE AGENT	  	
		
	SIGNED by	  	)
		  	)
	for and on behalf of	  	)
	CRÉDIT AGRICOLE CORPORATE	  	)
	AND INVESTMENT BANK	  	)
	in the presence of:	  	)

  
 118 

 Execution Copy 

 

			
	JOINT MANDATED LEAD ARRANGERS	  	
		
	SIGNED by	  	)
		  	)
	for and on behalf of	  	)
	CRÉDIT AGRICOLE CORPORATE	  	)
	AND INVESTMENT BANK	  	)
	in the presence of:	  	)
		
	SIGNED by	  	)
		  	)
	for and on behalf of	  	)
	SOCIETE GENERALE	  	)
	in the presence of:	  	)
		
	SIGNED by	  	)
		  	)
	for and on behalf of	  	)
	KFW IPEX BANK GMBH	  	)
	in the presence of:	  	)
		
	SIGNED by	  	)
		  	)
	for and on behalf of	  	)
	HSBC BANK PLC	  	)
	in the presence of:	  	)

  
 119EX-10.16

 Exhibit 10.16 

Execution Copy 
  

 
 [*] THE CONFIDENTIAL PORTION HAS
BEEN OMITTED PURSUANT TO A REQUEST FOR CONFIDENTIAL TREATMENT AND THE OMITTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION 

FINCANTIERI CANTIERI NAVALI ITALIANI SpA 

and 
 EXPLORER NEW BUILD, LLC

 SHIPBUILDING CONTRACT 

for Hull No. 6250 

 INDEX 
  

	
	Art. Index
	
	1. Subject of the Contract
	2. Vessel’s Classification - Rules and Regulations - Certificates
	3. Vessel’s Characteristics
	4. Builder’s Supply - Owner’s Supply
	5. Approvals - Supplies by Third Parties
	6. Hull Number
	7. Inspection of Construction
	8. Delivery
	9. Price
	10. Payment Conditions
	11. Defaults by the Owner
	12. Trials
	13. Speed - Liquidated Damages
	14. Deadweight - Liquidated Damages
	15. Stability
	16. Passengers and Crew Accommodation Capacity
	17. Fuel Oil Consumption - Liquidated Damages
	18. Vibrations and Noise
	19. Maximum Amount of Liquidated Damages
	20. Termination of the Contract - Liquidated Damages to be paid by the Builder
	21. Property and Intellectual Property Rights
	22. Responsibility after Delivery
	23. Insurance
	24. Modification to Plans and Specification
	25. Guarantee - Liability
	26. Permissible Delay
	27. Confidentiality
	28. Contract Expenses
	29. Assignment of the Contract
	30. Law of the Contract - Disputes
	31. Address for Correspondence
	32. Effectiveness of Contract

 THIS SHIPBUILDING CONTRACT is dated June 5, 2013 and made between: 

(1) EXPLORER NEW BUILD, LLC, a company organised and existing under the laws of the State of Delaware, with its registered office care of CSC, 2711
Centerville Road, Suite 400, Wilmington, DE 19808, United States of America, and with its principal office at Miami, Florida, 33122, 8300 NW 33rd Street, Suite 101 (the “Owner”),
and 
 (2) FINCANTIERI - CANTIERI NAVALI ITALIANI S.p.A., a company organised and existing under the laws of
the Republic of Italy, with registered office in Trieste, via Genova, 1, fiscal code 00397130584 (the “Builder”), 
 NOW IT IS HEREBY
AGREED AS FOLLOWS: 
 ARTICLE 1 

Subject of the Contract 
 1.1. The Builder
undertakes at one of its yards (the “Yard”) to design, construct, survey and test in accordance with its usual construction standards for new luxury passenger ships, and to complete and deliver at the Yard to the Owner, who
undertakes to accept delivery, of one passenger cruise ship (the “Vessel”) in accordance with this Contract, the Specification No. P.8528 dated February 2013 (the “Specification”), and the General Arrangement Plan
Version B dated February 13, 2013 (the “GAP”) and the other plans and drawings referred to in the Specification (together with the GAP, the “Plans”) which, signed by the parties, constitute an integral part of
this Contract even if not annexed hereto. 
 1.2 Except as otherwise provided in the Specification, the standards for the internal decoration of the
Vessel’s public areas and passenger cabins shall be at least as high as the standards in the corresponding parts of M.V. Riviera (ex-Hull 6195) (the “Reference Ship”). 

1.3 This Contract, the Specification and Plans are intended to complement and supplement each other, and the Specification and Plans are also intended to
explain each other. The Specification and Plans shall form an integral part of this Contract. In the event of any conflict between this Contract and the Specification or Plans, the provisions of this Contract shall prevail. In the event of any
conflict between the Specification and the Plans, the provisions of the Specification shall prevail. In the event of any conflict between one Plan and another, the later in date shall prevail. 

1.4 Each party agrees to use all reasonable efforts to make timely decisions in a speedy and effective way and to deal fairly with each other and at all times
to act in good faith in relation to all matters concerning this Contract. 
 ARTICLE 2 

Vessel’s Classification - Rules and Regulations -
Certificates - 
 (Standard of Construction) 

 

	2.1	The Builder shall design, construct, test and deliver the Vessel under the survey of a Classification Society to be separately agreed in writing by the Owner and the Builder from among those referred to in the
Specification (the “Classification Society”) and in accordance with the rules, regulations and other requirements of the Classification Society for the Class notation described in section 005 of the Specification for a vessel
registered under the Marshall Islands flag (the “Flag Authority”). 

	2.2	The Vessel shall comply with the rules, regulations and other requirements of the Classification Society (the “Class Rules”), and with the laws, regulations, rules and other requirements of the Flag
Authority and the other regulatory authorities referred to in the Specification (the “Regulatory Rules”), that are in force as of the date of this Contract and which will be compulsory for the Vessel considering its actual keel
laying date. 

  

	2.3	All Classification, certification, testing and survey charges to be paid to the Classification Society or any other body or authority in relation to the design, construction, survey, testing or delivery of the Vessel,
its machinery and equipment shall, unless otherwise expressly stated in the Specification, be for the account of the Builder. 

  

	2.4	The decisions by the Classification Society, the Flag Authority and other regulatory authorities that are to issue the certificates referred to in the Specification shall be binding on both parties as to the
Vessel’s compliance or non-compliance with the Class Rules or (as the case may be) the Regulatory Rules. However, this provision shall not absolve the Builder from any of its obligations to comply with
the requirements of the Specification and the Plans that exceed the requirements of the Class Rules or the Regulatory Rules. 

  

	1.	To the extent required by the Specification, the Builder shall carry out all such pre-delivery works, and shall hold and pass all such pre-delivery inspections and tests, as may be feasible and possible (subject to and
taking into account the availability of USPH and USCG to come to the Yard upon reasonable advance notice from the Builder) to reasonably ensure that upon the Vessel’s first arrival in the United States of America following delivery under this
Contract, USPH and USCG approve the Vessel for immediate, full and unrestricted passenger service. 

 ARTICLE 3 

Vessel’s Characteristics 
  

	3.1	The Vessel shall have the following main dimensions and characteristics, as more particularly described in the Specification and the Plans: 

 

	(A)	Main Dimensions 

  

	 	•	 	Length between perpendiculars Approximately 193 metres 

  

	 	•	 	Length overall Approximately 223 metres 

  

	 	•	 	Breadth at water line Approximately 31 metres 

  

	 	•	 	Deadweight at Design Draught Approximately 5000 metric tons 

 Approximately means +/- 1%. 

(B) Passenger Cabins 

Single cabins 12 
 Entry Level
cabins 48 
 De Luxe cabins 226 

Penthouse Suites 49 
 Superior
Suites 22 
 Master Suites 6 

Grand Suites 6 
 Total 369 

 Crew Cabins 

Crew quadruple 2 
 Crew double
210 
 Crew single cabins 57 

P.O. cabins 16 
 Officer cabins
30 
 Senior officer suites 4 

Captain class 3 Guest cabins 4 

Total 326 
  

	(C)	Life Saving Equipment 

 Total number of persons on board for purpose of life saving equipment - 1360.

  

	(D)	Machinery - Diesel Electrical Generators/Propulsion Plant 

 The
main propulsion machinery shall consist of four (4) elastically mounted medium speed diesel engines driving electrical generators and two (2) frequency controlled electric motors of 9 MW each, each driving one fixed pitch propeller. 

(E) Main Diesel Generating Sets 
 The main
diesel generating sets shall comprise four (4) medium speed, four stroke, trunk piston diesel engines, turbocharged, fresh water cooled, started by compressed air of the following number and type: 

4 x MAN 14V32/44CR, MCR 7840 kW at 720 rpm 
 Total installed
machinery power 31.360 MW (ISO 3046-1) 
 As an alternative, the following configuration can be installed: 

2 x Wartsila 16V32, MCR 8800 kW at 720 r.p.m. 
 2 x Wartsila
12V32, MCR 6600 kW at 720 r.p.m. 
 Total installed machinery power 30.800 MW (ISO 3046-1) 

Fuel oil: HFO to ISO 8217:2010 RMK 380 with maximum viscosity of 380 cSt at 50°C. 

(F) Speed 
 With all four diesel
alternators in operation and with the propulsion motors developing each at the motor flange 7.75 MW the Vessel, at design draught even keel, in lack of wind, in smooth, deep and currentless sea water at 20 °C, with clean hull and propellers and
fin stabilizers folded in hull, shall reach a speed of [*] knots. 
  

	1.	 The foregoing main characteristics may be slightly modified - but without reducing the passenger or crew capacity of the Vessel or affecting any of
the Builder’s obligations under Articles 13 to 18 - if the Builder should deem such modifications necessary to fulfill the contractual requirements in respect of the deadweight, stability and speed. Before making any such modifications the
Builder shall notify 

	 	
the Owner in writing and provide a reasonably detailed explanation of the reasons for and effects of the modifications proposed by the Builder. Any reasonable comments or objections made by the
Owner shall be taken into account by the Builder. 

 ARTICLE 4 

Builder’s Supply - Owner’s Supply (Architect) 

 

	4.1	Those items of equipment identified as Owner’s supplies in section 0013 of the Specification will be provided by the Owner (the “Owner Supplies”). Any excess of the relevant agreed weight shall be
treated as a modification under Article 24 (in respect of any weight and/or stability impacts). The Builder shall supply all other items of equipment and materials that are required for the construction, outfitting and completion of the Vessel in
accordance with this Contract and the Specification. 

  

	4.2	The parties will agree to a mutually acceptable schedule for delivery of the Owner’s Supplies which takes due account of the Builder’s timetable for construction of the Vessel and the time reasonably required
by the Owner to obtain the Owner’s Supplies. Thereafter the Owner will arrange for the Owner’s Supplies to be delivered to the Builder’s designated storage facility in accordance with this agreed schedule. The Builder will assist the
Owner’s representatives in clearing customs and taking delivery at the Builder’s storage facility of each shipment of Owner’s Supplies. 

  

	4.3	The Builder shall be responsible, at its own expense and risk, for keeping the delivered Owner’s Supplies safely stored and well protected, and for the careful handling of the delivered Owner’s Supplies.

  

	4.4	Subject to Article 4.5, the Builder shall arrange, at its own expense and risk, for the loading, installation and arrangement on board the Vessel (including, without limitation, the framing and mounting of artwork) of
the Owner’s Supplies, and such loading, and installation and arrangement work shall be covered by the Builder’s guarantee under Article 25. 

  

	4.5	The Owner shall arrange for proper and timely transmission to the Builder of all data and information required in connection with Owner’s Supplies. The Owner shall also arrange and be responsible for its
subcontractors providing all customary and necessary activities, assistance, services, supervision and other support in relation to the installation and subsequent testing, pre-commissioning and commissioning of any equipment or machinery items of
Owner’s Supplies. Upon completion of the installation, testing, pre-commissioning and commissioning of Owner’s Supplies, the Owner’s subcontractor shall issue a compliance letter stating (if such be the case) that the work has been
completed. 

  

	4.6	The Owner’s Supplies shall be delivered to the Builder in proper condition for loading, installation or arrangement on board the Vessel. 

 

	4.7	The Builder shall notify the Owner in writing as soon as reasonably practicable of any deficiency or damage in the supply, condition or performance of any Owner’s Supplies. As soon as reasonably practicable
following its receipt of such notice, the Owner shall take all such steps as may be necessary to procure the supply of any missing Owner’s Supplies or the rectification of any deficiencies in delivered Owner’s Supplies unless the Builder
or any of its representatives (including subcontractors) is responsible for the deficiency or damage. 

	4.8	All risk and responsibility for any inherent deficiency, damage, poor quality or poor efficiency of any Owner’s Supplies shall rest with the Owner unless the Builder or any of its representatives (including
subcontractors) is responsible for any such deficiency, damage, poor quality or poor efficiency. 

  

	4.9	Fuel oils and lubricants for the set up of the plants on board and for all the shop tests of such plants and the trials of the Vessel afloat will be supplied by the Builder and at the Builder’s cost and expense.

  

	1.	The Owner undertakes to supply the detailed architectural drawings (the “Architectural Drawings”) developed from the Plans relevant to the public rooms, passenger open decks, passenger cabins, and the
other areas, rooms and spaces on the Vessel to which passengers would have access under normal operating conditions (the “Public Spaces”). The Architectural Drawings will be drawn up at Owner’s expense and delivered to the
Builder in accordance with the schedule referred to in Article 4.11 (the “Public Room Schedule”). The Architectural Drawings will conform with the agreed structure and layout of the relevant areas of the Vessel, including frame
spacing, steel structure, engine casing, vertical and horizontal air and cable ducts and other necessary matters. The general standard for quality and quantity of materials and complexity of the execution of the interior of the Public Spaces to be
defined by the Architectural Drawings will be in accordance with the reference standards referred to in the Specification. The Owner shall supply the Architectural Drawings in compliance with the Public Room Schedule (or such longer period as may be
agreed by the Builder (acting reasonably) if the Owner requests an extension of any due date referred to in the Public Room Schedule). Without limiting the contractual remedies (e.g. in respect of additional direct costs incurred by the Builder), it
is acknowledged that any failure in so delivering the Architectural Drawings or in indicating or approving any materials, colors, etc. beyond the relevant due date in the Public Room Schedule may also cause a Permissible Delay provided that the
Builder complies with the notice requirements set out in Article 26. 

  

	2.	The documentation relevant to Public Spaces will be issued and acted on by both parties in accordance with the provisional Public Room Schedule attached as Annex 1. The Builder will advise the Owner within three
(3) months from the date of this Contract of the final Public Room Schedule for delivery and scope of the design concepts for the Vessel. The Builder will promptly provide the Owner’s architect with any required information regarding the
layout. The parties mutually acknowledge that the strict compliance with the Public Rooms Schedule is crucial for the Vessel’s production schedule, and for the related design and purchasing activities. 

 

	3.	The Owner undertakes to provide all the elements and the detailed drawings relevant to the Owner’s Supplies mentioned in the Specification. The Owner shall also take care to select all materials (types, colours,
etc.) provided in the Specification in strict compliance with the Builder’s construction program, as updated from time to time in accordance with this Contract, and the requirements of the Classification Society, the Flag Authority and the
other regulatory bodies. 

  

	4.	The Owner will be entirely responsible for the Owner’s Supplies (including their insurance cover, unless otherwise agreed by the parties), subject to the other provisions of this Contract, so that, amongst other
things, in case any of the Owner’s Supplies should not be delivered in time, any delay directly caused to the Builder’s program will be a Permissible Delay provided that the Builder complies with the notice requirements set out in Article
26, and any actual additional direct costs and damages incurred by the Builder will be charged to the Owner. 

 ARTICLE 5 

Approvals - Supplies by Third Parties 

 

	5.1	Wherever mentioned in this Article, the term “drawings” shall mean plans, schedules, subcontractors supply order specifications and other materials and matters that require the Owner’s approval in
accordance with the Specification. 

  

	5.2	In accordance with the procedures and other requirements provided in the Specification: the Builder shall deliver to the Owner for approval the drawings for the construction, outfitting and completion of the Vessel; and
the Owner shall return to the Builder one copy of these drawings, either approved or supplemented with its remarks, suggestions or proposals. If the Buyer fails to return any drawings to the Builder within twenty one (21) days from the date of
their delivery in accordance with the Specification (or such longer period as may be agreed by the Builder (acting reasonably) if the Owner requests an extension of such twenty one (21) day period), such drawings will be considered as approved.

  

	5.3	The Builder will send to the Owner, within three (3) months from date of this Contract, the completion and dispatch schedule for the drawings referred to in Article 5.2. Any amendments to such schedule will be
promptly notified in writing to the Owner. 

  

	5.4	The Builder will take into consideration the remarks, suggestions or proposals, if any, by the Owner, as follows:- 

  

	(A)	If the Owner’ remarks, suggestions or proposals are covered by Builder’s contractual obligations, the Builder shall promptly carry them out without claiming any costs and shall promptly supply the Owner with
the relevant amended drawings in order to describe and confirm the modification made. 

  

	(B)	If the Owners’ remarks, suggestions or proposals are not covered by Builder’s contractual obligations, they shall be handled according to Article 24. 

 

	(C)	If the parties disagree about whether or not any of the Owner’s remarks, suggestions or proposals are covered by the Builder’s contractual obligations then, subject to any contrary direction in writing by the
Owner, the Builder shall carry them out provided that the Owner undertakes by written notice to the Builder to accept its position in respect to the Contract Price (or other variations). Such acceptance will not prejudice the Owner’s ability to
refer the disagreement for resolution pursuant to Article 30. 

 Amendments in respect of drawings referred under sub-paragraph (B) above according to Article 24 will in turn be submitted for the approval of the Owner, with the same procedure as outlined above with respect to the modification. 

	5.5	Approval or deemed approval of such drawings will not affect the responsibility of the Builder for the due completion of the Vessel and the fulfillment of the Builder’s other obligations under this Contract, the
Specification and the Plans. 

  

	5.6	The Owner undertakes to use all reasonable commercial efforts to ensure that the requested approvals are given in the shortest time reasonably practicable within the period referred to in Article 5.2. 

 

	5.7	Subject to the following provisions of this Article 5, the Builder shall have the right to subcontract part of the supply and work to be carried out under this Contract on the building site or elsewhere to reputable and
suitably qualified and experienced contractors to the European passenger cruise ship construction sector provided that the main construction work and the main work of assembly of the Vessel’s sections, as well as the installation of machinery,
equipment and outfit, shall be carried out by the Builder at the Yard. 

  

	1.	The subcontractors for items included in the makers’ list agreed between the Owner and the Builder (the “Makers’ List”) shall be one of the makers listed in the Makers’ List in relation
to the relevant item. The Owner and Builder may by agreement from time to time add to or remove names from the Makers’ List. 

  

	2.	In relation to those items specified in the Makers’ List, the Builder shall select from the companies listed in the Makers’ List. The specifications in respect of the relevant supply will be sent to the Owner
for comment, and the Owner will submit its comments in accordance with the procedures referred to in Article 5.2 above. Certain of the items in the Makers’ List, have been designated as special items (the “Special Items”). In relation
to such Special Items, once the Builder has completed the tendering process and made its choice, the Builder will inform via email the Owner accordingly. The Owner will be entitled to indicate, within 5 days of such notice, a different maker of its
preference. The Builder will promptly provide the specifications of both makers, together with any price difference or other possible impacts. If the Owner requests the Builder to select its preferred maker, then the Builder will accept the
Owner’s request provided that if the supply from the Owner’s preferred maker is more expensive than the supply by the Builder’s selected maker, the increased cost and any other effects for the Builder (such as in relation to weight,
time of delivery, engineering, installation, etc) will be treated as a modification for the Owner’s account under Article 24. The Builder will use all reasonable commercial efforts to minimize any cost differentials between different makers.

  

	1.	During the period commencing on the date when the parties have signed this Contract and ending on the date when the Vessel is delivered to the Owner, all contacts with the makers of supplies for which the Builder is
responsible will be carried out through the Builder. However, after the Builder has received offers from possible makers and after the indication of the Builder’s choice, the Owner and its representatives may communicate direct with makers in
connection with post delivery matters including, without limitation, the supply of additional spare parts, warranty extensions, maintenance programmes and other after sales services. 

 

	2.	Upon finalization of the orders, the Owner will be provided with such information as it may reasonably request in order to verify the scope of supply, technical specifications and performance of the equipment supply or
work carried out or to be carried out by makers and the Builder’s other subcontractors (or proposed makers and subcontractors). 

  

	3.	Nothing in this Article 5 shall affect the Builder’s other obligations under this Contract nor diminish the responsibility of the Builder in respect of the design, materials and workmanship required of under this
Contract. The supplies from and work of all makers, subcontractors and other third parties will be covered by the Builder’s guarantee under Article 25. 

 ARTICLE 6 

Hull Number 
  

	6.1	The Vessel will be identified as hull number 6250. 

  

	1.	As soon as reasonably practicable after delivery to the Yard or a storage facility of the Builder elsewhere, all materials, machinery and other equipment intended to be used in or for the Vessel shall be marked with the
above hull number in order to identify them as belonging to the Vessel. The Builder may not use any such materials, machinery or other equipment in or for the construction of any other ship, without the prior written approval of the Owner. Nor may
the Builder permit the use in or for the construction of the Vessel of any materials, machinery and equipment marked with another hull number. 

ARTICLE 7 
 Inspection of Construction

  

	7.1	During the Vessel’s construction, the Owner shall have the right to have the Vessel and all engines, machinery, outfit, furnishings and other materials inspected and supervised by its authorized representatives, to
whom the Builder shall grant free access - during working hours - to the Vessel, its yards and workshops. The Builder shall also obtain the same right of access to the
workshops and other premises where parts intended for the Vessel are subcontracted by the Builder. The inspections and supervisions carried out by the Owner or its representatives shall not absolve the Builder from or reduce any of its obligations
and responsibilities under this Contract, the Specification and the Plans. 

  

	7.2	Throughout the period during which the Vessel is under construction the Builder will conduct its proper quality control program of inspections, testing and supervision by a team of the Builder’s staff dedicated for
this purpose. The Owner’s authorized representatives shall wherever practicable work together with the Builder’s staff and jointly sign protocols in respect of items approved by them. The Owner shall appoint a project manager to lead the
Owner’s on-site team of authorized representatives; one Owner’s representative shall be fully empowered to approve, accept work and agreed modifications, extra prices and all consequences thereto within parameters to be confirmed by the
Owner in writing. If the Builder considers the conduct of any member of the Owner’s on-site team to be in serious contravention of the Yard’s internal rules and regulations, the Owner will investigate the Builder’s complaint and
ensure that any misconduct does not recur. 

  

	7.3	The Owner’s authorized representatives shall promptly notify the Builder in writing of any defect or deficiency that they discover and regard as being in non-compliance with
the requirements of this Contract, the Specification or the Plans. 

  

	7.4	No action or omission by the Owner or any of its authorized representatives under this Contract, nor any approval by the Owner or its authorized representatives with respect to any work, inspections, tests, trials,
plans or other documents shall relieve the Builder from its responsibility for the successful completion of the Vessel in accordance with this Contract, the Specification and the Plans, or from its obligation under Article 25. 

	7.5	The Builder shall take due account of and implement reasonable remarks by the Owner or its authorized representatives, within the limits of the Builder’s contractual obligations under this Contract, the
Specification and the Plans. 

  

	7.6	The Owner’s authorized representatives shall observe the work rules prevailing at the yards and other premises of the Builder and its subcontractors premises as far as they may be applicable. The Owner’s
authorized representatives shall also address their remarks exclusively to the Builder’s appointed representatives. 

  

	7.7	The Builder shall prepare an inspection and tests schedule and shall give to the Owner reasonable advance notice (taking into account the location of each set of inspections, tests and trials) about the dates of major
inspections, tests (including, without limitation, main engine bench tests) and trials including those to be carried out at subcontractors’ premises in accordance with the Specification. On completion of the inspections, tests and trials of
major items, protocols of acceptance will be drawn up and signed by the authorized representatives of the Owner and the Builder and, wherever required, by the Classification Society. After each protocol of acceptance has been signed on behalf of the
Owner and the Builder and, where required, the Classification Society, the area(s), item(s) or system(s) referred to in the protocol will not be re-opened for further inspections, tests or trials except where this is reasonably required in
connection with any required alteration, modification, dismantling, investigation, remedial or other work. If the Builder re-opens any area(s), item(s) or system(s), it must promptly give the Owner’s authorized representatives written notice
specifying the relevant area(s), item(s) or system(s), the reason for the re-opening and the related steps taken or work done by the Builder. The Owner’s authorized representatives, acting reasonably, will then be entitled to carry out further
inspections, tests or trials in relation to the re-opened area(s), item(s) or system(s) and the related steps taken or work done by the Builder 

  

	7.8	The Builder shall provide to the Owner’s representatives, for their inspection and supervision tasks, suitably furnished office space at the Yard equipped with lavatories, direct call national and international
telephone lines, word processors, wireless internet access, telefax and the other facilities described in the Specification. The telephone and telefax expenses, and the expenses of any additional services from time to time requested by the
Owner’s representatives, will be charged to the Owner at cost but all other expenses in connection with such office space shall be for the account of the Builder. 

ARTICLE 8 
 Delivery 

 

	1.	Title and risk of loss of or damage to the Vessel shall rest with the Builder until the time when the parties sign and exchange the protocol of delivery and acceptance referred to in Article 8.3, at which point in time
title and risk shall pass to the Owner. 

	2.	After completion of all tests and trials in accordance with the Contract and the Specification, and after completion of all other work required to be completed under this Contract, the Specification and the Plans, the
Builder shall tender delivery of the Vessel safely afloat, moored alongside a quay at the Yard; clean to the Builder’s usual standards for luxury passenger ships and in all other respects ready and suitable for embarkation of the Vessel’s
crew and passengers; with full title guarantee and free from all claims, encumbrances and liens whatsoever; and together with the documents required by the Specification, which may be include usual interim or provisional certificates if, without
fault of the Builder, permanent certificates are not available at the time of delivery provided that: 

  

	(i)	the certificates and other documents provided to the Owner at delivery must be (a) valid for a minimum period acceptable to the Owner (acting reasonably) from the date of delivery, and (b) free of any
conditions, qualifications, recommendations or restrictions that could impair the Owner’s ability to register the Vessel under the rules of the Flag Authority or to utilize the financing required to fund payment of the installment of the
Contract Price payable on delivery of the Vessel, or that could prevent the Vessel from entering - and remaining - in full and unrestricted passenger revenue service on the Owner’s scheduled commencement date, and without any material
restrictions to the Vessel’s operational capabilities; and 

  

	(ii)	the Builder must deliver permanent certificates and other documents to the Owner as soon as reasonably practicable after delivery and in any case before the expiry of any interim or provisional certificates provided at
delivery. 

 At the same time the following further documents will be tendered for delivery to the Owner: 

 

	(A)	In respect of the Contract Price: (i) a commercial invoice, in one original and in one certified true copy, for the total final Contract Price (including evidence of sums dues for modifications and other sums
payable to the Builder at delivery), duly executed by the Builder in favor of the Owner; (ii) certified true copy bank statements of the Builder evidencing its receipt of the first, second, third and fourth installments of the Contract Price;
and (iii) certified copy commercial invoices in respect of modifications confirming the total amount invoiced to the Owner for modifications. 

  

	(B)	A declaration by the Builder, in one original and in one certified true copy, that the Vessel is delivered to the Owner free and clear of all claims, encumbrances or other liens whatsoever upon the Vessel and the
Owner’s title thereto, and in particular, that the Vessel is absolutely free of all burdens in the nature of imposts, taxes or charges imposed by any of the national, provincial, local or port authorities of Italy prior to or in connection with
delivery and acceptance of the Vessel. 

  

	(C)	A Builder’s Certificate, in one notarized original and in one certified true copy. 

  

	(D)	The “as built” drawings and other technical construction and trials documents in the formats and numbers referred to in the Specification (any missing documents may be delivered at a further stage, subject to
the proviso at the end of the first paragraph of Article 8.2). 

  

	(A)	A certified true copy of a declaration duly executed by the Builder and delivered to the Owner’s designated financing bank attesting the origin of the exported goods and declaring all the amounts transferred abroad
for any reason in connection with the performance of the Contract. 

  

	(B)	If so required by the Owner, a certified true copy of the Builder’s duly executed and delivered Exporter Declaration to Società Italiana per le Imprese all’Estero - SIMEST S.p.a, the original of which I
to be delivered to the Owner’s designated financing bank on the delivery date. 

  

	(C)	Such documentary evidence as the Owner (acting reasonably) may require to show that the documents to be provided by the Builder at delivery were signed by duly authorized representatives of the Builder (which will be
deemed satisfied if the Public Notary attending the delivery meeting confirms the sufficiency of the powers of the Builder’s representative who sign the delivery documents), including a certified true copy of the power of attorney pursuant to
which the authorized signatory (ies) of the Builder signed the documents referred to in this Article 8.1 and their specimen signature(s). 

	(D)	If so required by the Owner, one original and one certified copy of the acknowledgement of the notice of assignment of the Owner’s rights under the post-delivery guarantee given by the Builder under Article 25 of
this Contract. 

  

	(E)	Any other documents reasonably required by the Owner, and reasonably within the Builder’s control or ability to deliver, to enable the Owner to utilize the financing required to fund payment of the installment of
the Contract Price payable on delivery of the Vessel or to register the Vessel with the Flag Authority. 

 8.3 The Builder and the Owner will
sign a notarized protocol of delivery and acceptance, in one (1) original and two (2) notarially certified copies, to confirm the final acceptance of the Vessel by the Owner and to record the time at which the Vessel was delivered pursuant
to this Contract. Immediately after execution of such protocol, the Builder shall present one (1) notarially certified copy of the protocol of delivery and acceptance at the Italian registry of ships under construction (“RNC - Registro
Navi in Costruzione”) and apply for the Vessel to be permanently deleted from the Italian registry. As soon as possible thereafter the Builder shall obtain and provide the Owner with an original certificate issued by the Italian registry
confirming that the Vessel has been permanently deleted from the registry free and clear of all claims, encumbrances or other liens whatsoever upon the Vessel. 

8.4 The Owner shall at its cost take all such steps as may be required to register the Vessel with the Flag Authority, and the Owner’s completion of this
registration process shall not be a condition to completion of the delivery process referred to in this Article 8 and neither a condition to transfer all amounts due and payable on delivery of the Vessel pursuant to Article 10. 

8.5 If:- 
  

	(A)	the documents in conformity with Article 8.2 are tendered by the Builder; and 

  

	(B)	the Vessel has been duly completed in accordance with this Contract, the Specification and the Plans, apart from any minor non-conformities as defined in Article 8.10, delivery shall be considered as carried out to all
effects even if the Owner refuses to sign the protocol of delivery and acceptance (save for other actions the Builder may decide to adopt). 

  

	8.6	Subject to the proviso at the end of this Article 8.6, the Vessel shall be delivered to the Owner, at the Yard, in accordance with this Contract the Specification and the Plans and provided the payments hereinafter
specified are made within the terms set forth, upon completion of the Vessel in accordance with this Contract, the Specification and the Plans on 30th June 2016, as extended by the period by
which the delivery of the Vessel is actually delayed by reason of any cause or event delaying or preventing the Builder from tendering delivery of the Vessel as provided in Article 26, for modifications affecting the Vessel as provided in Article
24, or for late payments under Article 11, or for any other Permissible Delay to which the Builder is entitled under the express provisions of this Contract (such date as thereby extended being referred to as the “Delivery Date”).
The proviso referred to above is that if the Effective Date defined in Article 32 has not occurred within June 2013, the 30th June 2016 date specified above must be reconfirmed or reset by
written agreement of the parties before this Contract becomes effective. 

 The Builder shall give the Owner twelve (12), six (6), three
(3) and one (1) month’s firm written notice of the expected delivery date. 

	8.7	Following delivery, the Builder will use all reasonable commercial efforts to allow the Vessel to remain alongside the delivery quay (free of any pier charges to the Owner during such stay) for up to three (3) days
after the date of delivery. 

  

	8.8	If the Vessel is not delivered to the Owner in accordance with the terms of this Contract, the Specification and the Plans on or before the Delivery Date the following shall apply: 

(A) If the Vessel is not delivered to the Owner in accordance with the terms of this Contract, the Specification and the Plans by the Delivery Date, and if
the Builder has provided written notice of the delay, specifying the revised delivery date, to the Owner at least [*] calendar days before the Delivery Date, then the Builder shall pay the Owner as final liquidated damages an amount of €[*]
each calendar day of delay in delivery (and pro rata) beyond midnight in Italy on the day falling [*] running days from the Delivery Date. 
 (B) If the
Vessel is not delivered to the Owner in accordance with the terms of this Contract, the Specification and the Plans by the Delivery Date, and if the Builder has provided written notice of the delay, specifying the revised delivery date, to the Owner
between [*] and [*] calendar days before the Delivery Date, then the Builder shall pay to the Owner as final liquidated damages (and not as a penalty) an amount of €[*] for each calendar day of delay in delivery (and pro rata) beyond midnight
in Italy on the day falling days from the Delivery Date. 
 (C) If the Vessel is not delivered to the Owner in accordance with the terms of this Contract,
the Specification and the Plans by the Delivery Date, and if the Builder has provided written notice of the delay, specifying the revised delivery date, to the Owner between [*] and calendar [*] days before the Delivery Date, then the Builder shall
pay to the Owner as final liquidated damages (and not as a penalty) an amount of €[*] for each calendar day of delay in delivery (and pro rata) beyond midnight in Italy on the day falling [*] running days from the Delivery Date. 

(D) If the Vessel is not delivered to the Owner in accordance with the terms of this Contract, the Specification and the Plans by the Delivery Date, and if
the Builder has provided written notice of the delay, specifying the revised delivery date, to the Owner between [*] calendar days before the Delivery Date, or if the Builder has provided no notice of delay to the Owner before the Delivery Date,
then the Builder shall pay to the Owner as final liquidated damages (and not as a penalty) an amount of €[*] each calendar day of delay in delivery (and pro rata) beyond midnight in Italy on the day falling [*] from the Delivery Date. 

8.9 If delivery of the Vessel to the Owner in accordance with this Contract has not been made for whatever reason or combination of reasons (except for delays
actually occasioned by modifications under Article 24 or by any Owner’s Delay), by the date falling [*] days from the original delivery date then in any such case the Owner may, at any time thereafter, terminate this Contract with the
consequences referred to in Article 20. 
 8.10 The Owner will not be entitled to refuse delivery of the Vessel on account of minor non-conformities,
meaning any minor defects or minor outstanding works which do not (i) impair the Owner’s ability to register 

 
the Vessel under its chosen flag or to utilize the financing required to fund payment of the installment of the Contract Price payable on delivery of the Vessel, or (i) render the Vessel
unseaworthy, or (iii) prevent the safe operation of the Vessel , or (iv) prevent the Vessel from entering - and remaining - in full and unrestricted passenger revenue service on the Owner’s scheduled commencement date, and without any
material restrictions to the Vessel’s operational capabilities provided that (a) the Builder undertakes (at its expense, risk and time) to complete the works required to remedy such minor non-conformities, without discomfort to the
passengers or other impairment of their use and enjoyment of the Vessel, as soon as reasonably possible after delivery in accordance with a remedial plan and timetable to be approved in writing by the Owner before delivery (the Builder agreeing that
for the use by its makers, subcontractors or suppliers precedence will be given to crew cabins); and (b) for such minor non-conformities, the guarantee period referred to in Article 25 shall commence on the date of completion of the relevant
remedial works rather than on the date of delivery of the Vessel, and Article 25 shall be deemed amended accordingly. The Builder shall prepare a remedial action plan and timetable to be agreed with the Owner in good time before delivery. 

8.11 If it is not practicable before delivery for the Builder to demonstrate the contractual performance of any of the specified equipment or the contractual
performance of any of the specified technical systems of the Vessel in its intended operating conditions, the Builder will demonstrate such performance as soon as practicable after delivery, and if it is not practicable to do so within [*] days
after delivery compliance or non-compliance shall be determined by calculations (approved by the Classification Society or by any other Class Registry reasonably acceptable to both parties). In case of
deficiencies in performance the Builder will remedy such deficiencies under the guarantee contained in Article 25 save that, for such deficiencies, the guarantee period referred to in Article 25 shall commence on the date of completion of the
relevant remedial works rather than on the date of delivery of the Vessel, and Article 25 shall be deemed amended accordingly. 
 8.12 From the time when
the first work inspections and approvals are to be made and given on behalf of the Owner, the designated representatives of the Builder and the Owner shall keep a written list of defects and deficiencies (including minor non-conformities). The
Builder and the Owner, each acting reasonably, shall update this list at face to face or telephonic progress meetings to be held at regular intervals (as the period may require) as the parties may from time to time agree (“progress
meeting”) to reflect the addition and removal of defects and deficiencies. At such progress meetings the Builder will also update the Owner about the construction schedule progress. 

8.13 All defects and deficiencies in the Vessel as notified by the Owner at the time of delivery (or which were not apparent upon a reasonable external
examination at delivery of the Vessel), shall be covered by the Builder’s guarantee under, and shall be remedied in accordance with, Article 25. 

 8.14 The Builder will give the Owner’s crew access to the Vessel with effect from 2 weeks before the
expected delivery date. The parties will co-ordinate and co-operate with each in good time to confirm and implement such access arrangements provided that the same shall not delay or interfere with the Builder’s work to complete the Vessel in
time for the expected delivery date. 
 ARTICLE 9 

Price 
  

	1.	The Owner shall pay to the Builder for the Vessel the price of €343,000,000 (euro three hundred and forty three million) (the “Contract Price”). This is a fixed price and may be adjusted only in
strict accordance with, and subject to, the express provisions of this Contract. 

  

	2.	The Contract Price includes allowances of: (i) €[*] for the catering area (including culinary school catering equipment), local entertainment and carpet installation in the Vessel; (ii) €[*] for
supplies such as loose furniture, spare parts, artworks and other services linked to the construction, decoration and operation of the Vessel; and (iii) €[*]. for the installation of a scrubber system and any further technical
improvements or upgrades, including any relating to the configuration of the engines. These allowances shall be adjusted, applied and accounted for in the manner agreed by the parties and documented separately from this Contract. 

ARTICLE 10 
 Payment Conditions 

 

	10.1	The Contract Price shall be paid in the following installments: 

 (A) [*] %, being €[*] within [*] banking
days in New York and Rome after the Effective Date (as defined in Article 32); 
 (B) [*] %, being €[*] on the later of the start of steel cutting and
the date falling [*] months prior to Delivery Date; 
 (C) [*] %, being €[*] on the later of keel laying and the date falling [*] months prior to
Delivery Date; 
 (D) [*] %, being €[*] on the later of float out and the date falling [*] months prior to Delivery Date; and 

(E) [*] %, being €[*] on delivery of the Vessel. 
 If any
of the above events will be achieved on a date different from that originally planned, the Builder will promptly inform the Owner of the new date. 

 To enable timely funding of each installment, the Builder will inform the Owner at least [*] days in advance of
the expected due date for payment of each installment. 
 10.2 The Owner’s obligations to pay each installment of the Contract Price referred to in
Article 10.1 (A) to (D) shall, in the case of each such payment, be subject to and conditional upon the Owner’s receipt of the Builder’s invoice. 

10.3 The amount due by the Owner or the Builder for each modification to the Specification and the Plans shall be accounted for as follows: (i) [*] % of
the agreed modification amount shall be paid by the Owner within [*] days after the Owner’s receipt of the invoice issued pursuant to the agreement relating to the modification, or (as the case may be) credited by the Builder within [*] days
after the date of the agreement relating to the modification; and (ii) [*] % of the agreed modification amount shall paid by the Owner, or (as the case may be) credited by the Builder, on delivery of the Vessel. 

10.4 Liquidated damages, if any, for delivery, capacity, speed, deadweight or fuel oil consumption will be determined on delivery of the Vessel (or, in the
case of termination of this Contract for delay in delivery, on termination) and the relevant amount will be paid on delivery or (as the case may be) on termination of this Contract. 

10.5 The Owner shall not delay or discontinue any payment required under this Contract for any reason whatsoever except in the event of the Builder tendering
delivery of the Vessel or the delivery documents when it or they are not in deliverable condition under this Contract or the proper termination of this Contract or the total loss of the Vessel under this Contract. Exceptions, disputes or claims, if
any, by the Owner against the Builder shall be asserted separately, pursuant to the provisions set forth in Article 30. 
 ARTICLE 11 

Defaults by the Owner 
  

	11.1	If the Owner fails to pay, on the relevant due date, any installment of the Contract Price or other amount due under this Contract, then the Owner shall pay to the Builder - as
from the due date - interest at the rate of [*] % per annum over three (3) months EURIBOR as displayed on the relevant page of the Telerate or Reuters screen from time to time or, if such display is not
available at any time, as quoted by a similar reliable source (the “Contract Rate”). 

  

	11.2	Moreover, the Builder shall be entitled to one day’s extension in the delivery time of the Vessel for each day of delay in the payment of any sum referred to in Article 11.1 and if the delay in payment exceeds [*]
days as from the date of the Owner’s receipt of written notice of non-payment from the Builder, then the Builder shall have the option to suspend all production of the Vessel until payment of the unpaid sums (and interest thereon at the
Contract Rate) has been received by the Builder. 

  

	11.3	If the delay in the payment of any sum referred to in Article 11.1 exceeds [*] days from the date of the Owner’s receipt of written notice of non-payment from the Builder, then at any time thereafter the Builder,
even if it has elected to suspend its obligations under Article 11.2, or if any of the events specified in Article 11.7 occurs and is continuing, may give to the Owner notice in writing declaring the Contract terminated and claiming damages.

  

	11.4	To recover payment of the damages for default of the Owner under this Article 11 the Builder shall have the option (but shall not be bound) to sell the Vessel before or after having completed it, together with (at the
Builder’s discretion) any Owner’s Supplies in the Builder’s possession, without prejudice to any other of the Builder’s rights. 

	11.5	If the Builder elects to sell the Vessel (together with any such Owner’s Supplies), then the sale shall be effected by auction or by private sale, on such terms and conditions at such price as the Builder (acting
reasonably) shall determine. If the net proceeds of such sale and the installments of the Contract Price already paid by the Owner do not cover the direct damages and expenses incurred by the Builder (including, without limitation, direct costs and
expenses incurred by the Builder in connection with the sale, and any direct costs and expenses incurred by the Builder in constructing and completing the Vessel after termination of the Contract), the Owner shall be liable for the difference.

  

	11.6	If the Owner fails to take delivery of the Vessel upon a valid tender of the Vessel and the delivery documents for delivery in accordance with the terms of this Contract then, without prejudice to any other right of the
Builder, [*] days after the Owner’s receipt of the Builder’s written notice that the Owner has wrongfully failed to take delivery of the Vessel and provided that the Owner does not take delivery within such [*] day period, the whole of the
outstanding balance of the Contract Price payable under Article 10 and all of the other outstanding payments due from the Owner shall be regarded as having fallen due immediately. 

 

	11.7	The events referred to in Article 11.3 are:- 

  

	(A)	a bona fide petition, whether voluntary or involuntary, is filed and is not dismissed within [*] days or an effective resolution is passed for the insolvency, liquidation, reorganization or winding up of the Owner
(other than for the purposes of a reconstruction or amalgamation or reorganization not involving or arising out of the insolvency and by which the obligations of the Owner are effectively maintained or transferred to the reconstructed, amalgamated
or reorganized entity) under the laws of any applicable jurisdiction; or 

  

	(B)	a receiver, trustee, liquidator or sequestrator of, or for, the Owner or any substantial portion of the property of the Owner is appointed or the Owner makes an assignment of the whole or a substantial part of its
assets for the benefit of its creditors; or 

  

	(C)	the Owner is unable to pay or admits its inability to pay its debts as they fall due or if a moratorium shall be declared in respect of any indebtedness of the Owner or the Owner ceases to carry on its business or makes
any composition with its creditors generally or is declared insolvent or goes into liquidation. 

 11.8 The Owner shall indemnify the Builder
for any actual additional cost, burden or damage directly caused by the Owner’s breach of the Owners’ Supply provisions or other Owner’s obligations. 

ARTICLE 12 
 Trials 

 

	12.1	The Vessel shall run the following testing trials: 

  

	(A)	Berth trials as specified in the Specification. 

  

	(B)	Official sea-trials as provided in the Specification during which the trial speed and the propulsion motors output and revolutions shall be determined in accordance with paragraph
(F) of Article 3.1. 

 An endurance test as well as all other trials and tests included in the sea trial program in the Specification
shall also be carried out with recording of measurements of all parameters, enabling determination of performance relevant to each test. 
 The trials
program will be timely agreed upon by Owner and Builder. 
  

	12.2	The speed runs and endurance test shall be run at the draft of [*] metres or at the draft attainable by ballasting the Vessel with ballast water using tanks and compartments intended for this purpose. 

As far as practicable the draft and conditions shall be as close as possible to the corresponding draft and other actual trial conditions at which tank model
test have been carried out. Should such speed trial draft and other actual trial conditions be other than the draft and conditions specified in paragraph (F) of Article 3.1, the speed, the propulsion motors’ output and the revolutions
corresponding to the latter draft and conditions shall be determined on the basis of the results recorded at the sea trials by means of data from the model tests carried out with the final hull form and design propellers. 

 

	12.3	All trials and measurements will be conducted in a manner and to an extent as prescribed in a detailed schedule based on the Specification. The methods to be used are to be selected by the Builder, in accordance with
the common practice (as followed on the Reference Ship and approved by the Owner, acting reasonably). 

  

	12.4	The Builder has the right to subcontract speed and power measurements to an independent model basin or research institute. However, the Owner will be kept fully informed and allowed to observe and ascertain measurements
recorded during the trials as if the Builder had carried out the tests with its own personnel. 

  

	12.5	Should any adverse weather condition prevent the Builder from carrying out properly the official trial on the day scheduled therefor, the Builder has the right to postpone the trial or such part of it as deemed
necessary. In such case the Builder shall be entitled to an extension of the Vessel’s delivery time covering the whole period of postponement, subject to and in accordance with Article 26, provided that the Vessel’s delivery is actually
delayed by such postponement and provided further that the Builder shall promptly carry out the postponed trial or part as soon as conditions allow. 

  

	12.6	The Builder will be entitled to conduct a preliminary sea trial, enabling checking and adjustment of the propulsion plant and the detection of defects and deficiencies, such as excessive noise and vibration, and their
correction in good time. The preliminary sea trial will take place as soon as the Vessel is sufficiently completed for this purpose. The Owner’s representatives will be entitled to attend such preliminary trial and will be given reasonable
advance notice by the Builder. Any adjustment to the functioning of the power generation and propulsion plants and system associated otherwise shall be within the normal limits prescribed by the makers of the propulsion plant and will not in any
case cause conditions of undue stress or any other abnormal condition in the Vessel, its machinery and equipment. 

  

	1.	The sea trials program will include trials for the determination of the steering and manoeuvring characteristics of the Vessel. 

  

	1.	The Builder shall have the right to repeat any trial whatsoever after giving reasonable notice to the Owner, without prejudice to the Owner’s rights under the other provisions of this Contract. Where a test
memorandum is available, the parties shall sign it to signify the acceptance of the test and relevant equipment, machinery or system (or to rise specific remarks, as the case may be). Such repetition will be in the Builder’s time and cost.

	12.9	The official sea trials will be carried out using Fuel Oil with a viscosity up to 380 cSt at 50°C 

  

	12.10	All risks and expenses for the trials will be borne by the Builder who, during the sea trials, will provide the necessary crew at its own risk and expense. 

 

	12.11	Should any breakdowns occur during the trials, entailing their interruption or irregular performance and breakdown cannot be repaired by the normal means available on board, the trial so affected will be cancelled and
will be repeated by and at the expense of the Builder. 

  

	12.12	If the breakdowns could be repaired by the normal means available on board, the trials, with the previous agreement between the Owner and the Builder, will be continued and considered as a valid trial.

  

	12.13	The Builder shall give the Owner [*] days notice of the anticipated date of the sea trials. 

  

	1.	Provided the Builder will make available to the Owner the results of the sea trials within [*] days after completion of sea trials, within the following [*] days, the Owner shall give the Builder a notice in writing, of
completion and acceptance or (as the case may be) rejection of the results of the sea trials. 

 12.15. In the event that the Owner rejects
the results of the sea trials as not conforming to this Contract or to the Specification or the Plans, the Owner shall in reasonable detail indicate in its notice of rejection in what respect the Vessel, or any part or equipment thereof, does not
conform to this Contract and/or the Specification and/or the Plans. 
 12.16 In the event that the Owner fails to notify the Builder as aforesaid of the
acceptance or the rejection, together with the reason therefore, of the sea trials within the period as provided above, the Owner shall be deemed to have accepted the sea trials of the Vessel. 

12.17 Acceptance of the results of the sea trials as above provided shall be final and binding so far as conformity of the Vessel to this Contract and the
Specification and the Plans to the extent demonstrated on such trials is concerned and shall preclude the Owner from refusing formal delivery of the Vessel as hereinafter provided, on the grounds of non conformity of the Vessel in respect of items
whose conformity has been demonstrated and accepted during the sea trials so long as the Builder complies with all other requirements for delivery under this Contract. For the avoidance of doubt, the parties confirm that if any damage/failure occurs
or is discovered between the Owner’s acceptance of the results of the sea trials and delivery that are not minor non-conformities as defined in Article 8.10 the Owner may require the Builder (at the latter’s cost and time) to remedy the
same to the standards required by this Contract and to demonstrate the same to the Owner before the Builder tenders the Vessel for Delivery. 
 12.18 Should
any fuel oil or lubricating oil in storage tanks or unbroached barrels but excluding oils in circulation, greases and ship’s stores, including fresh water furnished by the Builder for the sea trial remain on board the Vessel at the time of
acceptance thereof by the Owner, the Owner agrees to buy the same from the Builder at the Builder’s cost price. 
 12.19 If the Owner supplies any
spares and other parts for any stage of the trials that are consumed during the trials, at Owner’s option the Builder will replace the relevant items or reimburse the Owner at its cost price. 

 ARTICLE 13 

Speed - Liquidated Damages 

 

	13.1	Should the speed of the Vessel, at the design draft of [*] metres determined in accordance with Article 3.1(F), under the conditions set out in the Specification, as determined in Article 12, be lower than [*] knots,
the Builder shall pay to the Owner, as final liquidated damages, the following cumulative amounts:- 

  

	•	 	for the [*] of a knot of less speed: €[*] 

  

	*	for the [*] of a knot of less speed: €[*] 

  

	•	 	for the [*] of a knot of less speed: €[*] 

  

	•	 	for the [*] of a knot of less speed: €[*] 

  

	•	 	for the [*] of a knot of less speed: €[*] 

  

	•	 	for the [*] of a knot of less speed: €[*] 

  

	•	 	for the [*] of a knot of less speed: €[*] 

  

	*	for the [*]of a knot of less speed: €[*] 

 with fractions being counted in proportion. 

Should the speed of the Vessel determined as aforesaid be less than [*] knots, then the Owner, as an alternative to receiving the foregoing liquidated
damages, shall have the option to terminate this Contract with the consequences provided for in Article 20. 
 ARTICLE 14 

Deadweight - Liquidated Damages 

 

	1.	The Vessel’s deadweight - as determined in the Specification - in sea water of 1.025 specific gravity on the mean draft of [*] metres
from the base line will not be less than [*] metric tons. 

  

	14.2	Should the Vessel’s deadweight be less than [*] metric tons, then the Builder shall pay to the Owner, as final liquidated damages, an amount of €[*] for each metric ton of lesser deadweight for the first [*]
metric tons and €[*] for the subsequent [*] metric tons, with a fixed free allowance of [*] metric tons. 

  

	2.	Should the Vessel’s deadweight be less than [*] metric tons, then the Owner, as an alternative to receiving the aforementioned liquidated damages, shall have the option to terminate this Contract with the
consequences provided for in Article 20. 

 ARTICLE 15 

Stability 
  

	15.1	The Vessel’s stability characteristics shall be such as to fulfill the requirements of the Class Rules and the Regulatory Rules set out in Article 2, and to ensure the Vessel’s sea-keeping characteristics and
seaworthiness. 

	1.	An inclining test for the determination of the Vessel’s stability characteristics shall be carried out in accordance with the provisions of Classification Society. 

 

	2.	(A) If necessary to enable the Vessel to comply with the requirements of the Class Rules and the Regulatory Rules set out in Article 2, the Builder may use the double bottom void tanks for ballast water; such tanks to
be coated as specified in the Specification for ballast tanks and to be provided with ballast suctions and sounding pipes both port and starboard. 

  

	(A)	If necessary in order to fulfill the deadweight commitments in accordance with Article 3.1 of the design draught may be increased. 

In either (A) or (B) above or a combination of both, the design draught may be increased up to a maximum of [*] metres and the design draught
referred to in Article 3.1(F), 12.2, 13 and 14.1 shall be correspondingly increased. 
 The foregoing provisions do not relieve the Builder of its
responsibility to comply in all respects with the specified deadweight, speed and range of the Vessel (as specified in Article 3), with the increased design draft. 

If the Vessel’s stability characteristics shall not fulfil the requirements of the Class Rules or the Regulatory Rules set out in Article 2, the Owner
shall have the option to terminate this Contract with the consequences provided for in Article 20. 
 ARTICLE 16 

Passengers Accommodation Capacity and Noise / Vibration 
  

	16.1	The capacity of the passenger and crew accommodation is specified in Article 3, and in the Specification and Plans. 

  

	16.2	[NOT USED.] 

  

	16.3	In the event that, except in the case of prior written agreement between the Builder and the Owner, the number of the passenger cabins is less than [*], then the Owner, as an alternative to receiving, as final
liquidated damages, the amount specified in Article 16.9 for each missing cabin, shall have the option to terminate this Contract with the consequences provided for in Article 20 hereof. 

 

	1.	If when the Builder tenders delivery of the Vessel any passenger cabin is not usable as a cabin for the Owner’s intended service with the Vessel, after taking due account of the allowed tolerances, owing to excess
noise or vibration levels as set forth in the Specification, then the Builder shall undertake to adopt the required remedial actions in accordance with a written remedial plan acceptable to the Owner or, alternatively, the Owner may require the
Builder to pay to the Owner the following final liquidated damages in respect of each such cabin: 

  

	2.	Comfort Class: If, for whatever reason, the Vessel fails to obtain the certificate of compliance with the Comfort Class specified in the Specification, then the Builder shall pay to the Owner, as final liquidated
damages for this particular failure, an amount of €[*]. 

  

	3.	Notwithstanding the above regarding the Comfort Class certificate, the liquidated damages detailed in Articles 16.7.1 and 16.7.2 shall apply. 

	4.	Noise, Vibration and Thruster Vibration  

  

	1.	Noise: If the Specification limits are exceeded in any passenger cabin then the following liquidated damages will apply, after [*] dbA of grace: 

 

	•	 	from [*] to [*] dbA: €[*] per cabin and €[*] per suite 

  

	•	 	from [*] to [*] dbA: €[*] per cabin and €[*] per suite 

  

	•	 	above [*] dbA: €[*] per cabin and €[*] per suite. 

 If the limits referred to above are exceeded by
more than [*] dbA in more than [*] % of the passenger cabins the Owner will be entitled to terminate this Contract with the consequences provided for Article 20. 
  

	2.	Vibration: If the Specification limits are exceeded in any passenger cabin then the following liquidated damages will apply, after [*] mm per sec of grace: 

 

	•	 	from [*] to [*] mm per sec: €[*] per cabin 

  

	•	 	from [*] mm per sec: €[*] per cabin 

  

	•	 	from [*] mm per sec: €[*] per cabin 

  

	•	 	above [*] mm per sec: €[*] per cabin or public space (mean value). 

 If the limits referred to above are
exceeded by more than [*] mm per sec in more than [*] % of the passenger cabins the Owner will be entitled to terminate this Contract with the consequences provided for Article 20. 

16.7.3 Thruster Vibration: If vibration caused by the thrusters exceeds: 
  

	*	[*] mm per sec (with a tolerance of [*] mm/sec). in any passenger cabin, the Builder shall pay liquidated damages of €[*] per cabin; and 

 

	*	[*] mm per sec (average value, with a tolerance of [*] mm/sec) in any dining venue, the Builder shall pay liquidated damages of €[*] per space. 

 

	16.8	Without prejudice to the foregoing provisions and to the Builder’s obligations under this Contract, the parties will work co-operatively together: (i) to identify any areas where impact, noise and vibration
could be an issue and to agree acceptable limits and solutions for prevention; and (ii) to agree to acceptable vibration levels relating to the operation of the Vessel’s thrusters. 

 

	16.9	The Builder shall pay as liquidated damages for each missing cabin the amounts detailed below:- 

[*] cabins deficiency: €[*] for each Single cabin; and 

€[*] for each Entry level cabin. 

[*] cabins deficiency: €[*] for each Single cabin; and 

€[*] for each Entry level cabin. 

In order to avoid the loss of cabins in the categories of Deluxe and above the Builder may adjust the cabin mix. If after the cabin mix
adjustment the missing number of Single cabins exceeds [*], then the Owner will be entitled to terminate this Contract in accordance with and with the consequences provided for in Article 20. 

 ARTICLE 17 

Fuel Oil Consumption - Liquidated Damages 

 

	17.1	For the main diesel engines a shop test shall be carried out in accordance with the Specification. During such shop test the specified fuel consumption shall be ascertained and corrected to the design parameters.

  

	17.2	For this purpose the shop test shall be run on marine diesel fuel oil with each diesel engine developing [*] % MCR at [*] revolutions. The measured fuel consumption shall be corrected to a reference lower calorific
value of [*] kilojoules per kg and ISO 3046/1 standard conditions. The fuel consumption of the main propulsion plant so corrected shall not exceed [*] grams per kWh, including the engine driven pumps (lube oil and high temperature cooling water) for
both engine types listed in Article 3.1 (E) Should the engine speed and/or fuel consumption of the actual diesel engines selected pursuant to the Makers’ List be different than the [*] rpm and/or [*] grams/kWh given above, then such
engine speed and/or fuel consumption shall be replaced with the corresponding value of actual diesel engines in this Article 17.2 and in Articles 17.3 and 17.4 below. 

 

	17.3	With respect to any of the engines, should the corrected fuel consumption be in excess of [*] % but less than [*] of [*] grams per kWh for both engine type listed in Article 3.1 (E) , the Builder shall pay to the
Owner, as liquidated damages and not by way of penalty, an amount of €[*] for each full one per cent and pro rata for each fraction thereof in excess of [*] % of [*] grams per kWh for both engine types listed in Article 3.1 (E) save and
except that the Builder shall have the right to remedy any defect causing such excessive fuel consumption and repeat the trial. 

  

	17.4	With respect to any of the engines, should the corrected fuel consumption be in excess of [*] % of [*] grams per kWh for both engine type listed in Article 3.1 (E), the Builder shall pay to the Owner, as liquidated
damages and not by way of penalty, an amount of € [*] for each full one per cent and pro rata for each fraction thereof in excess of [*] % of [*] grams per kWh for both engine types listed in Article 3.1 (E) save and except that the
Builder shall have the right to remedy any defect causing such excessive fuel consumption and repeat the trial. 

  

	17.5	With respect to any of the engines, should the corrected fuel consumption be in excess of [*] % of [*] grams per kWh for both engine types listed in Article 3.1 (E) the Owner, as an alternative to receiving the
above mentioned liquidated damages, shall have the option to refuse the defective engine, save and except that the Builder shall have the right to remedy any defect causing such excessive fuel consumption and repeat the trial. 

ARTICLE 18 
 Vibrations and Noise 

 

	1.	The noise and vibration permissible levels, calculations and investigation for the prediction thereof, exciter tests measurements, and precautions to be carried out by the Builder shall be in accordance with the
provisions of the Specification. 

	1.	Subject to Article 16, in case the measurements of said levels should register any exceeding value, the Builder shall be entitled to take any appropriate remedial actions (at its cost, time and risk) within the
expiration of the guarantee period (or, if later, and to the extent reasonably required by the Owner, at the first dry docking of the Vessel), subject however to the agreement of the Owner in respect to the timetable and the remedial action plan, in
order to avoid any disturbances to passengers. 

 ARTICLE 19 

Maximum Amount of Liquidated Damages 
 The
amount of the liquidated damages referred to in Article 8 (delivery), 13 (speed), 14 (deadweight), 16 (capacity, noise and vibration) and 17 (fuel consumption), shall in no case whatsoever exceed in aggregate [*] % of the Contract Price, and
individually - for each item referred to above - [*] % of the Contract Price. The Owner shall waive its entitlement to recover any damages in excess of this maximum amount. 

If delay in delivery for which the Builder is responsible exceeds the point at which the Builder is liable to pay liquidated damages under article 8, the
Owner may terminate the Contract, with the consequences provided for in Article 20, provided that the Owner can clearly demonstrate that the delay in delivery will continue for longer than [*] days from the original delivery date (as extended in
accordance with Article 8.9). 
 Each of the liquidated damages entitlements provided for in this Contract represents a genuine pre-estimate by the parties
of the relevant loss to the Owner and each such entitlement shall take effect as such and not as a penalty. However, if any such provision is found for any reason to be void, invalid or otherwise inoperative so as to disentitle the Owner from
claiming liquidated damages, such provision will be deemed deleted from this Contract to the extent it refers to liquidated damages and the balance of the provision and the other provisions of this Contract will remain in full force and effect. In
any such case the Builder will be liable to pay general damages to the Owner in respect of the relevant breach of its obligations under this Contract provided that the Builder’s liability in such circumstances will not exceed the Builder’s
liability to pay liquidated damages if the relevant provision had not been deemed deleted. 
 ARTICLE 20 

Termination of the Contract - 

Liquidated Damages to be paid by the Builder 
  

	20.1	The Contract may be contractually terminated by either party only under the express provisions of this Contract. If this Contract is terminated by the Owner under Articles 8, 13, 14, 15, 16, or 17, or paragraphs 2 or 3
of this Article, the Owner shall be entitled to: 

  

	(A)	the refund of all the sums paid to the Builder together with interest at the Contract Rate, compounded on a quarterly basis, running from the date of the Builder’s receipt of the relevant amount to the date of the
Owner’s receipt of the refund; and 

  

	(B)	the return of the Owner’s Supplies or the payment of an amount equal to the cost to the Owner of replacing those items of Owner’s Supplies that cannot be returned or that cannot reasonably be used by the
Owner; 

  

	(C)	in the case of termination pursuant to Article 8, the liquidated damages that would have accrued pursuant to Article 8.8 if the Vessel had been delivered on the date of termination (always subject to Article 19); and

	(D)	limited to the provisions mentioned under Article 20.3(B), if the Owner’s right to terminate this Contract becomes exercisable as a result of any gross negligence or willful default on the part of the Builder (or
those for whom the Builder is responsible under this Contract) the Owner shall, in addition to the refunds and payments referred to above, be entitled to claim and recover from the Builder as agreed liquidated damages for loss of this Contract, and
not as a penalty, an amount equivalent to [*] % of the Contract Price. 

 Except as otherwise expressly agreed and as provided in this Article
20.1, the Builder shall not have any further or other liability arising from this Contract following termination under the provisions referred to in this Article 20.1. 
  

	20.2	If: 

  

	(A)	a bona fide petition, whether voluntary or involuntary, is filed and is not dismissed within thirty (30) days or an effective resolution is passed for the insolvency, liquidation, reorganization or winding up of
the Builder (other than for the purposes of a reconstruction or amalgamation or reorganization not involving or arising out of insolvency and by which the obligations of the Builder are effectively maintained or transferred to the reconstructed,
amalgamated or reorganized entity) under the laws of any applicable jurisdiction; or 

  

	(B)	a receiver, trustee, liquidator or sequestrator is appointed of or for the Builder or any substantial portion of the property of the Builder; or 

 

	(C)	the Builder is unable to pay or admits its inability to pay its debts as they fall due or it suspends payment of its debts or ceases to carry on its business or makes any composition with its creditors generally or is
subjected to amministrazione controllata; 

 and in each of the above cases the construction of the Vessel is suspended for a period of more
than thirty (30) days for reasons other than any of the events specified in Article 26 (in any case in which such events excuse delay in construction); 

then, the Owner may immediately (but without being bound to do so) terminate this Contract by written notice to the Builder. 

 

	1.	If: 

 (A) the Builder is declared insolvent or goes into liquidation or winding-up under the laws of any
applicable jurisdiction; or 
 (B) the Builder (i) removes the Vessel from the Yard except as permitted by the express provisions of this Contract, or
(ii) assigns or transfers this Contract or subcontracts the whole or substantial part of the Vessel construction to be carried out by the Builder, except as permitted by the express provisions of this Contract, or (iii) fails to effect or
maintain any of the insurances required under Article 23; in each of such case, the termination may occur only upon a notification to the Builder providing a reasonable time (not less than thirty (30) days) to remedy the default, 

then the Owner may immediately (without being bound to do so) terminate this Contract by written notice to the Builder. 

 ARTICLE 21 

Property and Intellectual Property Rights 

21.1 During construction, the hull and/or parts of it, the engine and/or parts of it, the machinery, the equipments and/or outfitting materials and, in
general, whatever else is intended for the construction of the Vessel (excluding Owner’s Supplies and any other items supplied by the Owner), shall be the Builder’s property, and the Builder undertakes, in any case, not to dispose of the
Vessel and not to allow any mortgage or lien to be registered on the Vessel, without the Owner’s prior written consent. On the delivery of the Vessel, the Owner will acquire the whole property of the Vessel with full title guarantee and free
from all claims, encumbrances and liens whatsoever. 
 21.2 The Builder shall procure all such approvals and licenses, and pay all such royalties, license
fees or other similar charges, on or in connection with: (i) the Vessel; (ii) any equipment, parts and other items (apart from Owner’s Supplies) installed or incorporated in, stowed on or otherwise delivered with the Vessel; and
(iii) any part of the building work, as may be necessary to ensure that the same are delivered to the Buyer and may be owned and operated by the Buyer (and its successors, assignees and counterparties) without infringement of any patent, patent
right, copyright, trademark, trade secret or other intellectual property right. 
 21.3 The Builder shall indemnify fully, hold harmless and defend the
Owner from and against all losses which it may suffer or incur as a result of any actual or alleged infringement of any patents, patent rights, copyrights, trademarks, trade secrets or other intellectual property rights of any kind or nature on or
in connection with the Vessel or any equipment, parts and other items relating to the Vessel (other than Owner’s Supplies) or any part of the building work or the ownership or the use thereof by the Owner. In addition, at its cost and risk the
Builder shall take all such steps as may be required by the Owner to replace any infringing part with a non-infringing part which is satisfactory to the Owner. 

21.4 The Owner shall indemnify fully, hold harmless and defend the Builder from and against all losses which it may suffer or incur as a result of any actual
or alleged infringement of any patents, patent rights, copyrights, trademarks, trade secrets or other intellectual property rights of any kind or nature on or in connection with any Owner’s Supplies. In addition, the Owner shall ensure that the
Builder is permitted to use and handle all of the Owner’s Supplies for the purposes of this Contract so as enable the Builder to install the same on board the Vessel without any delay relating to license, use payments or any other intellectual
property matters. 
 21.5 All copyright, trade mark, patent and other intellectual property rights, and all similar rights of ownership or other proprietary
rights, created or developed by the Owner or any of its employees, agents, consultants or contractors in connection with the arrangement suggestions contained in the Owner’s proposed version of the GAP - REGENT - Luxury Cruise Newbuild
produced by IMA and dated 3rd September 2011 (the “IMA GAP”) - provided by the Owner to the Builder, is and shall remain the exclusive property of the Owner who reserves all
proprietary rights and other rights in and to the same. The Builder shall not have or obtain any rights of ownership or other rights in or to the IMA GAP except the right to use the same in order to perform its obligations under this Contract.
Notwithstanding the Owner’s rights in the IMA GAP, the Owner’s inputs in connection with the development of the Specification and the Plans, and the Owner’s provision of Architectural Drawings and approvals under this Contract, the
Builder shall be solely responsible for the design and construction of the Vessel. 
 21.6 Subject to Article 21.5, all copyright, trade mark, patent and
other intellectual property rights, and all similar rights of ownership or other proprietary rights, created or developed by the Builder or any of its employees, agents, consultants or contractors for creating the Specification and the Plans, with
the sole exception of the IMA GAP (the “Builder’s IPR”) in connection with the Vessel or any matter which is the subject of this Contract, is and shall remain the exclusive property of the Builder who reserves all proprietary
rights in and to the same. 

 21.7 The Owner shall not have or obtain any rights of ownership or other proprietary rights in or to any of the
Builder’s IPR. However, the Builder hereby irrevocably grants to the Owner, its permitted assigns, and to future owners, operators and managers of the Vessel a perpetual, transferable, non-exclusive worldwide royalty free license to copy,
communicate and use the drawings, manuals, plans and other documents to be provided by the Builder at delivery for the purposes of carrying out maintenance works, repairs or post-delivery modifications to the Vessel, to market the Vessel for charter
or sale, or to exercise its rights and perform its obligations under this Agreement. To the extent that any of the Builder’s subcontractors owns any of the Builder’s IPR, the Builder shall ensure that the relevant subcontractors grant
consent for the foregoing purposes. 
 ARTICLE 22 

Responsibility after Delivery 
 On delivery
of the Vessel to the Owner (and subject always to any agreed obligations of the Builder that will continue after delivery including in relation to the removal of minor non-conformities or the Builder’s completion of other works, tests or
measurements after delivery), every responsibility for the safety and generally for the condition of the Vessel is transferred to the Owner, remaining on the part of the Builder only the guarantee obligations set forth in Article 25. 

ARTICLE 23 
 Insurance 

 

	23.1	The Vessel under construction will be insured at the Builder’s expense, and at no cost to the Owner with leading insurance companies, under the “Institute Clauses for Builders’ Risks” (and usual
supplementary conditions) and against all risks covered by the “Institute War Clauses/Builders’ Risks”. 

  

	23.2	The insurance of the Vessel shall be effected for [*] of the installments of the Contract Price and other payments in respect of the Vessel actually paid to the Builder from time to time provided that - in consideration
of the actual stage of construction - a real risk of loss is reasonably foreseeable up to such amount. 

  

	23.3	At the request and cost of the Owner, the Builder will extend the insurance cover provided for in this Article 23 to cover [*] of Owner’s Supplies from time to time delivered to the Builder. 

 

	23.4	Subject to Article 23.5, the insurance monies will be allocated to the repair of damages or the reconstruction of the Vessel or (if the cover extension referred to in Article 23.3 is made) the repair or replacement of
the affected Owner’s Supplies. 

  

	23.5	In the event of the total loss (meaning an actual or constructive or arranged or compromised total loss) of the Vessel before delivery, or the abandonment of the Vessel before delivery, the Builder shall be entitled to
withdraw from this Contract or, if so agreed in writing by the Owner, to fulfill it but with the right to an agreed extension of the delivery term. If the Builder exercises its withdrawal right or the Owner refuses to agree to permit the Builder to
fulfill this Contract, the Owner shall be entitled to: 

  

	(A)	the reimbursement of the amounts already paid to the Builder on account of the Contract Price of the Vessel (plus interest at the Contract Rate from the relevant date of receipt by the Builder to the date of the
Owner’s receipt of the reimbursement payment); and 

  

	(B)	if the cover extension referred to in Article 23.3 is made, payment of an amount equal to the cost to the Owner of replacing those Owner’s Supplies that have been delivered to the Builder; 

	23.6	To guarantee the reimbursement referred to in Article 23.5, the insurance policies effected by the Builder will be bound in favor of the Owner and/or its assignees (up to the amount set out in Article 23.2 and, if
applicable, Article 23.3) and endorsed with appropriate loss payable clauses acceptable to the Owner (such acceptance not to be unreasonably withheld or delayed) providing for payment to the Owner of the amounts due to it. With the exception of
premiums for any cover extension made under Article 23.3, all premiums will be for the sole account of the Builder and neither the brokers nor the insurers will have any rights of recourse against the Owner or the Vessel or any rights to make any
deduction, set off or other withholding from any sums payable to the Owner or its assignees. As soon as practicable after issuance of the required insurance cover, the Builder will provide the Owner with a copy of the insurance cover note and other
usual available documents specifying the terms and underwriting security for the insurances. 

  

	23.7	If at any time before or at delivery the Vessel is subject to any damage that does not involve a total loss of the Vessel (as defined in Article 23.5), the Builder shall make good the damage so as to comply with the
requirements of this Contract as quickly as reasonably possible after the occurrence of the damage. The Builder shall apply any amounts recovered under the insurance provided for in this Article 23 to the costs of repair or replacement, including
any repair or replacement of lost or damaged Owner’s Supplies. 

  

	23.8	If the Owner does not receive any part of the sums payable to it under this Article 23 by reason of any act, neglect or default on the part of the Builder or any of those for which the Builder is responsible under this
Contract (including its subcontractors), the Builder will indemnify the Owner for the shortfall. 

 ARTICLE 24 

Modification to Plans and Specification 
  

	24.1	Subject to paragraph (3) of this Article, the Builder shall make the modifications, if any, to the Specification and Plans, requested by the Owner provided that in the reasonable opinion of the Builder such
modifications or accumulation of modifications do not adversely affect the Builder’s commitments to purchasers of other vessels from the Yard. 

  

	24.2	Both the requests by the Owner and their acceptance by the Builder will be made in writing. 

  

	24.3	The Builder shall notify the Owner in writing of the variations in price and other contractual conditions necessarily occasioned by the modifications allowed under Article 24.1, and shall execute such modifications only
upon written acceptance of the foregoing variations by the Owner. The Builder shall submit to the Owner for approval changes to the Plans and Technical Drawings resulting from such modifications. 

 

	1.	The Owner’s written acceptance must reach the Builder within [*] days from the date of the Builder’s notice or such longer period as the Owner may request and the Builder may agree in its reasonable
discretion. 

  

	24.5.	Should such an acceptance be not received within the terms set forth in Article 24.4, the Builder shall have the right to continue the Vessel’s construction as though no request for modifications had been made by
the Owner. 

	24.6.	In case of disagreement on the price and/or consequent variation of the contractual conditions concerning the modifications accepted by the Builder, the Owner may have the requested modifications executed, but shall
undertake by written notice to the Builder to pay the price requested (or the other variations quoted) by the Builder, according to the terms of Article 10.3 hereof. The Owner will remain free to submit the matter in dispute pursuant to Article 30.

 24.7 In the event that, subsequent to the date of signature of this Contract variations are made to the provisions compliance with which is
compulsory, the Builder shall notify the Owner in writing of the consequent modifications with their relevant price and other variations necessarily occasioned by such changes (which shall be determined having regard to the provisions of this
Article, except for section 24.6). 
 The Owner may first apply, or if such action should properly be taken by the Builder may require that the Builder
shall first apply, for a formal waiver of compliance with such changed requirements from the authority by whom the changes have been promulgated, if the Owner consider that the operation of the Vessel in its intended service would permit of such
waiver. In such event the Builder will fix a reasonable time limit after which if the waiver has not been obtained, the Builder will go on with the necessary variations. Any additional costs caused by the application for such waiver whether or not
obtained shall be for account of the Owner and the date of delivery of the Vessel if actually delayed thereby shall be extended by the time used in connection with the waiver application. 

24.8 In the case of any substantial modification (meaning any modification where the cost would be likely to exceed €[*], the Builder will provide a
detailed budgetary articulation (including engineering, material, manpower, cost of subcontractors and materials, Builder’s mark-up and other information requested by the Owner) in respect of the quotation submitted so as to afford the Owner
reasonable sufficient evidence of the activities, works and costs involved. 
 24.9 Each party will act reasonably in respect of the matters covered by this
Article 24. 
 ARTICLE 25 
 Guarantee - Liability 
 25.1 The guarantee of the Vessel shall have the validity of [*] calendar months commencing on the date
of the delivery of the Vessel to the Owner, extendable only by virtue of paragraphs (3) or (6) of this Article. 
 25.2 On the Owner’s
request, the Builder shall, at its own expense, repair and/or, if necessary, replace at one of its yards any defects or deviations in the Vessel or its design which are either notified by the Owner on delivery or which are not apparent on a
reasonable external examination at delivery of the Vessel, provided that such defects and deviations be notified in writing to the Builder on delivery (in the case of such as are discovered on or before delivery) or, at the latest, within one month
from the date of their discovery by the Owner. 
 25.3 If for operational reasons the guarantee dry docking of the Vessel cannot reasonably be carried out
before the expiration of the said [*] month period, then the guarantee dry docking can be postponed up to [*] months after delivery of the Vessel. The Builder will agree to perform the guarantee work at the postponed dry docking, provided that all
warranties items are jointly listed and properly specified within one month from expiry of the warranty period, and that the relevant suppliers and subcontractors agree to perform the work during the deferred period without any additional cost for
the Builder (subject however, notwithstanding 

 
Article 25.6, to a warranty of 6 months on the repaired work or replaced part), the Builder agreeing to use its reasonable commercial efforts to obtain the agreement of the relevant suppliers and
subcontractors. 
 If any of the Builder’s relevant subcontractors claim increased costs for carrying out any works required by reason of a postponed
guarantee dry docking against the costs that would have applied if the dry docking had been carried out within the [*] month period, the proven excess shall be for the Owner’s account provided that the Builder will promptly notify the Owner of
any such claims and, in co-operation with the Owner, the Builder will use its reasonable commercial efforts to minimize any such increased costs. The Owner, on advance written notice to the Builder, may decide to have an underwater inspection of the
Vessel’s hull upon expiration of the guarantee period, to assess the condition of the Vessel’s underwater parts. 
 25.4 The Builder shall provide
a guarantee to the Owner in relation to the paint for the Vessel on the same terms as that provided by the paint supplier to the Builder. Such guarantee shall be on the basis that the paintwork shall be carried out under the supervision of and to
the satisfaction of authorized representatives of the paint supplier. The Builder shall be responsible for arranging for such supervision. 
 25.5 Subject
to any agreements made by the parties at or before delivery (for example in relation to the remedy of minor non-conformities and other works, measurements and tests to be completed by the Builder at its expense, risk and time after delivery), the
Builder’s liability in relation to the Vessel, after the Vessel’s delivery, shall be limited to the obligations expressly set out in this Article 25 and the Builder and its sub-contractors and
suppliers shall have no additional liability whatsoever for damages in any way deriving from or connected either with the foregoing defects or deviations or with the repair and replacement processes relevant to the foregoing defects or deviations,
as is also excluded any other liability deriving from or in any way connected with any other cause not included in the foregoing guarantee obligation, which covers solely rectification and/or repair and/or replacement. 

25.6 If the Builder itself makes good any defects during the guarantee period specified in Article 25.1 as above, then the provisions of this Article 25 shall
apply to the parts repaired or replaced and the repair or replacement work for a period of [*] months after the repair or replacement was completed. 
 25.7
The Builder agrees within the terms of this Article 25 to investigate the cause of any recurring defect with a view to providing a satisfactory permanent remedy within the guarantee period. 

25.8 If it is necessary for the Vessel to be dry-docked solely for repairs or replacements of defects or deviations covered by the Builder’s guarantee
under this Article 25, the relevant expenses will be borne and paid by the Builder unless the Owner also carries out work for its account during the dry-dock period in which case the dry-dock costs will be allocated proportionately between the
parties. 
 25.9 The Owner shall indemnify and hold harmless the Builder for the expenses of repair or replacement borne by the Builder and which were
actually recovered by the Owner on the basis of the insurance policies, provided however that the Owner shall not be obliged to make any claim under its policy. 

25.10 The Builder shall not be liable to repair, replace or bear any responsibility for defects or deviations:- 

(A) due to normal wear and tear of the materials and damage whatsoever due to accidents involving the Vessel moored and/or at sea, or to fires, mismanagement
or negligence in the use of the Vessel by the Owner or by persons who, at the moment of the damage, were possessed of or governing the Vessel, or by any of their
persons-in-charge, official or agent; or 
 (B) affecting items of the
Owner’s Supply, but without prejudice to the Builder’s responsibility for defects or deviations in the work of installation of such items. 

 25.11 Should it prove necessary, in the reasonable opinion of the Owner and after reasonable consultation with
the Builder, owing to the conditions and location of the Vessel and the requirements of the Classification Society or the Flag Authority, or to avoid delays in carrying out urgent repairs or replacements, the Owner may have the rectification and/or
repair and/or replacement works covered by the Builder’s guarantee obligations carried out otherwise than in the Builder’s yards, provided that the Owner previously notifies the Builder, by letter or telefax, about the type and extent of
the defects or deviations to be remedied stating the reason of the necessity to have the works carried out elsewhere. The Builder shall reimburse the Owner the higher of (i) the retail costs which would have been applicable had the work been
carried out at the Yard in effecting such repairs and/or replacements, and (ii) the average of the costs charged for such work on a retail basis by Western European shipyards but not in any event more than the actual costs incurred by the Owner
for such work. 
 25.12 If so requested by the Builder, the Owner shall return, at the Builder’s cost and expense, the parts replaced. 

25.13 In any case, there is excluded any guarantee and/or liability of the Builder for repair and/or replacement work carried out outside any of the
Builder’s yards unless carried out on board the Vessel by the Builder’s workmen or its subcontractors or by persons arranged for by the Builder or its subcontractors. 

25.14 In any case the Vessel shall be taken at the Owner’s cost and responsibility to the place selected for the work to be carried out ready in all
respects for the guarantee work to be commenced. 
 25.15 If the guarantee stipulated by any manufacturers or suppliers of machinery, materials, equipment,
appurtenances and outfit furnished to the Builder and embodied in the Vessel exceeds the guarantee given by the Builder to the Owner hereunder, the Builder shall use its reasonable commercial efforts to arrange for such extended guarantee rights to
be assigned and made available to the Owner. 
 25.16 The Builder, at its own cost, is to have the right to investigate the validity of the Owner’s
guarantee claims either by the attendance aboard the Vessel (at its point of service) of an accredited representative or, if in the opinion of the Builder it is practicable to do so after suitable replacement is made, by the removal from the Vessel
and the transportation to the Yard of the defective part. 
 25.17 During the guarantee period, the Builder will be entitled to place on board a guarantee
technician approved by the Owner limited to the longer of: (i) the length of the Vessel’s first voyage after delivery; (ii) one month from delivery; and (iii) the date upon which the Builder completes the remedy of all defects
existing before delivery or discovered during the periods referred to (i) and (ii) above. The Owner will ensure that every assistance is given to the guarantee technician to allow him to inspect the operation of the engine and other
machinery and their maintenance. The Owner shall also ensure that the technician has a status on board not inferior to that due to the First Engineer. Should the Owner decide to extend the stay on board of the guarantee technician beyond the periods
referred to (i), (ii) and (iii) above, the Owner shall pay to the Builder remuneration for the extended period of the technician’s stay equal to that provided for in the ANIE tariffs. The presence on board of the technician shall in
no way affect the Owner’s liability regarding the good operation of the Vessel nor shall affect the liability of the Builder provided for in this Article or in relation to minor non-conformities. 

25.18. Subject to performance by the Builder of its obligations under this Article 25 and subject to any agreements made by the parties at or before delivery
(for example in relation to the remedy of minor non-conformities and other works, measurements and tests to be completed by the Builder at its expense, risk and time after delivery), the Owner waives, with the guarantee agreed upon in this Article
25, any further greater or different guarantee or liability by the Builder. 

 25.19 The guarantee period provided for in this Article 25 will be extended should the Vessel remain out of
service for more than [*] continuous days due to a defect for which the Builder is responsible, by on a day for day basis by any day during which the Vessel is actually prevented from entering or remaining in scheduled passenger service solely on
account of any defect or deviation covered by the Builder’s guarantee under this Article 25. 
 ARTICLE 26 

Permissible Delay 
  

	1.	Should the Builder be delayed or prevented from tendering delivery of the Vessel by the date specified in Article 8.3 owing to any cause or event reasonably to be considered beyond the control of the Builder including,
but not limited to, Acts of God; engagement in war or other hostilities, civil war, civil commotions, riots or insurrections; requirements of civil or military authorities; blockades or embargoes; vandalism; sabotage; epidemics or sickness above the
normal statistics of the Builder’s Yard; labor shortages or overtime abstensions or strikes or lockouts or other industrial actions, but only if any of such causes or events are general in nature and do not involve only the work force of the
Builder’s Yard and/or its subcontractors or their employees; earthquakes; landslides; floods; extreme adverse weather conditions not included in normal planning arrangements; failure of electric current; damage by lightning, explosions,
collisions, strandings or fire; accidents resulting in material damage to the Vessel; shortage of materials and equipment or inability to obtain their delivery, provided that such materials and equipment at the time of ordering could reasonably be
expected by the Builder to be delivered in time and were ordered in time; delays by land, sea or air carriers; casting, forging or machining rejects or defects in materials, machinery and equipment, provided that the same could not have been avoided
or detected by the Builder and/or its subcontractors or their employees using reasonable care; any other cause or event of a similar nature to any of the above reasonably to be considered beyond the control of the Builder; delays caused by delay of
the Classification Society or other bodies whose documents are required in issuing such documents; any Owner’s Delay (but without prejudice to any other rights of the Builder under this Contract); the effect of the foregoing on the
Builder’s other commitments; all the foregoing irrespective of whether or not these causes or events occur before or after the date hereinbefore specified as the date on which the Vessel is to be delivered; 

Provided that: 
  

	a)	the Builder shall have exercised, in connection with any such cause or event, all reasonable efforts to avoid or minimize their occurrence (to the extent, if any, that the any such cause or event could have been avoided
or minimized); and 

  

	b)	the Builder shall have exercised, in connection with any of such cause or event, all reasonable efforts to mitigate the duration and effects of such cause or event; 

then and in any such case the delivery date of the Vessel shall, subject to the following provisions of this Article 26, be extended by the number of working
days of delay actually incurred by the Builder in completing and delivering the Vessel in consequence of any of these causes or events. 
 The period of any
such permitted extension, and any other extension of the delivery date permitted by any of the other express provisions of this Contract, shall be a “Permissible Delay”. 

 26.2 As soon as reasonably possible and - in any case - within [*] days after the Builder’s management
(including its project team) becomes aware of the occurrence of any cause or event, or their effects on the Builder’s work under this Contract which it expects may give rise to a Permissible Delay, the Builder shall notify the Owner in writing
of the occurrence of the relevant cause or event. Thereafter the Builder will keep the Owner regularly informed about the steps taken, where applicable, to mitigate any delay in the completion and delivery of the Vessel and the predicted effects (if
any) on the Delivery Date. Further, as soon as reasonably possible after the occurrence of any cause or event that by its nature is continuing and - in any case - within [*] days after the end of any cause or event which may give rise to a
Permissible Delay, the Builder shall notify the Owner in writing that such cause or event has ended and of any Permissible Delay claimed by the Builder. Any failure by the Builder to comply with the notice requirements set out in this Article 26
will operate as a waiver by the Builder of its right to a Permissible Delay by reason of the occurrence of the relevant cause or event. Notwithstanding the foregoing provisions of this Article 26.2, if the cause or event giving rise to a claim for
Permissible Delay is an Owner’s Delay, then the Builder will not be obliged to give the notice referred to in the first sentence of this Article 26.2 in respect of such cause or event. However, when the relevant action has been taken by the
Owner, and if the Builder expects that the cause or event may delay or prevent the Builder from tendering delivery of the Vessel by the date specified in article 8.3, the Builder will notify the Owner of the Permissible Delay claimed by the Builder
in respect of the relevant Owner’s Delay. 
 26.3 Notwithstanding any provision to the contrary in this Contract, the Builder shall not be entitled to
claim a Permissible Delay under this Article 26 or any other Article of this Contract if and to the extent that the relevant delay was caused by a breach of any of the obligations of the Builder under this Contract or by the gross negligence or
willful misconduct of the Builder, its servants or agents or of any of the Builder’s subcontractors, their servants or agents. 
 26.4 For the purposes
of this Contract “Owner’s Delay” means any default action or omission on the part of the Owner including (without limitation) (a) any failure by the Owner to deliver any Owner’s Supplies or relevant data, information
or assistance, by the relevant due date under Article 4, or (b) any failure by the Owner to supply the Architectural Drawings or to indicate or approve materials, colors and other required matters by the relevant due date in the Public Room
Schedule, or (c) any extension of the delivery date by operation of Article 11.2. 
 ARTICLE 27 

Confidentiality 
 27.1 After the date of
this Contract, the parties will agree to the terms and publication date(s) of press announcements in relation to the construction of the Vessel. 
 27.2
Save as provided in Article 27.1, the parties shall treat as confidential and use all reasonable efforts to ensure that their respective agents, officers, employees, workmen, subcontractors, and other representatives treat as confidential, the
provisions of this Contract provided that: each party may, with the prior written consent of the other, disclose to any third party information relating to the matters referred to in this Article 4.2; and each party shall be entitled to
disclose any such information to their shareholders or prospective shareholders, bankers, auditors and/or legal advisors or to rating agencies (providing that such agencies are informed of the confidentiality restrictions relating to the information
so disclosed), or to such extent as may from time to time be required by law or contract or the rules or regulations of any applicable stock exchange or similar body. 

 ARTICLE 28 

Contract Expenses 
  

	28.1	All taxes, expenses, duties, stamps and fees levied by the Italian authorities, or the authorities of any other relevant countries, in connection with this Contract and the Builder’s activities hereunder shall be
borne and paid by the Builder. 

  

	28.2	Any taxes, duties, stamps and fees levied in any country in relation to the Owner’s activities under this Contract (including, without limitation, the Owner’s registration of the Vessel with the Flag Authority
and the costs and salaries of the Owner’s crew members during their time at the Yard, the direct purchasing of any service or item of supply) shall be borne and paid by the Owner. 

 

	28.3	This Contract shall be registered in Italy, at fixed tax payable by the Builder, according to Article 40 of Decree No. 131, dated April 26, 1986, by the President of the Italian Republic. 

ARTICLE 29 
 Assignment of the Contract

 29.1 Subject to the proviso to this Article 29.1, the Owner may assign any or all of its post-delivery rights under this Contract (i) to the
Owner’s financiers, or (ii) to any party to whom the Owner contracts the operation or management of the Vessel provided that no such assignment shall increase the scope of the Builder’s post-delivery obligations to the Owner or render
performance of such obligations more onerous for the Builder. 
 29.2 The Owner may assign or transfer this Contract to any member of the corporate group to
which the Owner belongs, upon prior written notice to the Builder and provided that in the reasonable opinion of the Builder such assignment/transfer does not otherwise affect its position or expectations under this Contract. In addition, subject to
obtaining the prior written approval of the Builder (which shall not be unreasonably withheld or delayed) and complying with any conditions reasonably required by the Builder, the Owner may transfer this Contract to any third party, provided also
that such assignment should not affect, in the Builder opinion, the proper completion of the Vessel construction. 
 29.3 The Builder shall not be entitled
to assign or transfer this Contract to any third party without the prior written approval of the Owner but it will be entitled to assign this Contract to a wholly controlled subsidiary upon prior written notice to the Owner and provided that in the
reasonable opinion of the Owner such assignment does not otherwise affect its position or expectations under this Contract, provided that the Builder shall be entitled to assign its right to receive payments due from the Owner under this Contract to
the banks or other financial institutions that finance the Builder’s construction of the Vessel. 
 ARTICLE 30 

Law of the Contract - Disputes 

 

	30.1	This Contract is governed by, and shall be construed and interpreted in accordance with, English law. 

  

	30.2	 If any disagreement or dispute of a technical nature arises between the parties before delivery in relation to the construction of the Vessel,
engines, materials or workmanship, it shall forthwith be referred to a technical expert (who shall act as an expert not as an arbitrator) nominated by agreement 

	 	
between the parties. The expert’s decision shall be final and binding upon both parties and the expert’s costs shall be borne equally by the parties. If the parties fail to agree upon
and appoint an expert within fourteen (14) days of a request by one party to do so, the dispute shall be determined as provided in Article 30.3. 

  

	1.	Without prejudice to Article 30.2, if any disagreement or dispute arises between the parties as to any matter regarding this Contract that cannot be settled by the parties themselves, the matter in dispute shall be
determined by a Board of three Arbitrators in accordance with the Arbitration Acts 1996 as enacted and amended. The arbitration shall take place in London. The relevant award shall be final. 

 

	2.	Each party agrees that neither party shall be liable to the other under or in connection with this Contract for any form of consequential, exemplary, indirect or special loss or damage of any nature whatsoever, however
caused and whenever arising. 

 ARTICLE 31 

Addresses for Correspondence 
  

	31.1	The Builder shall send all notices, letters and documents for the Owner in connection with or required under this Contract to the following addresses or such other address as may be notified by the Owner to the Builder:

  

	(A)	for all technical matters: Att. Mr Robin Lindsay, SVP Vessel Operations 

 Address: 8300 NW 33rd St, Suite 101, Miami FL 33122 USA 
 Telephone: +1 305 514 2235 

Email: rlindsay@prestigecruiseholdings.com 
 Telefax: +1 305 514
2297 
  

	(B)	for all legal and financial matters: Att. Jill Guidicy, VP Corporate Counsel 

 Address: as above

 Telephone: +1 305 514 2773 
 Email:
jguidicy@prestigecruiseholdings.com 
 Telefax: +1 305 500 2835 

and c.c. Mr Frank Del Rio, Chairman and CEO 

Telephone: +1 305 514 2301 
 Email: frankdelrio@
prestigecruiseholdings.com 
  

	31.2	The Owner shall send all notices, letters and documents for the Builder in connection with or required under this Contract to the following address or such other address as may be notified by the Builder to the Owner:

 Fincantieri Cantieri Navali Italiani S.p.A. 

Merchant Shipbuilding General Unit 
 Passeggio S.
Andrea 6 
 34123 Trieste, Italy 
  

	(A)	for all technical matters 

 Attention: Project Manager of Hull 6250 

 Telephone: +39 040 319 3485 

Telefax: +39 040 319 3890 

Email: (care of) barbara.ladich@fincantieri.it 
  

	(B)	for all legal and financial matters: 

 Attention: Head of Contract Dept. 

Telefax: 39 040-319 3890 

Email: MC-GCO@fincantieri.it 
 Whenever this
Contract requires that notice and/or notification shall be given in writing, such notice and/or notification may validly be given by letter, by telefax or by e-mail. 

All approvals or consents required under this Contract shall be given in writing by letter, telefax or email from the duly authorized representative of the
relevant party. 
 ARTICLE 32 
 Effectiveness of Contract

  

	1.	Notwithstanding signature of this Contract by both parties or any other provision of this Contract to the contrary, this Contract shall not have any legal effect whatsoever until the time on the date (the
“Effective Date”) when: the Owner has confirmed in writing to the Builder that it and its lenders have signed a final and binding term sheet detailing the main terms and conditions for the financing of the Contract Price; and the 30th June 2016 date specified in Article 8.6 has been reconfirmed or reset by written agreement of the parties, if a reset is required under Article 8.6. 

 

	1.	Notwithstanding signature of this Contract by both parties or any other provision of this Contract to the contrary, if by 31st July 2013 (subject to any extension agreed in writing by the parties) the Owner has not
executed final and binding definitive documents for the financing of the Contract Price, written notice of which shall be immediately sent by the Owner to the Builder, then either party may cancel this Contract by written notice given to the other
party at any time thereafter. In the event of the exercise by either party of its right to cancel this Contract under this Article, this Contract shall, with effect from such cancellation, be null and void and neither party nor any of its respective
parents, subsidiaries, affiliates or any of the officers or employees of any of the foregoing shall have any liability or obligation whatsoever under or in connection with this Contract or in connection with its cancellation, except that the Builder
shall immediately refund the payments previously made by the Owner under Article 10.1. 

 Authorized Signatures 

			
	Signed by )	  	
		  	)
		  	)
	Attorney in fact for and on behalf of )	  	
	 EXPLORER NEW BUILD, LLC )
 in the
presence of:-
	  	
		
	Signed by )	  	
		  	)
		  	)
	for and on behalf of )	  	
	FINCANTIERI - Cantieri Navali )	  	
	Italiani S.p.A. )	  	
	In the presence of:-

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00229-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00229-of-00352.parquet"}]]