Document:

International Swap Dealers Assoc., Inc Master Agreement and Schedule

 Exhibit 10.50 
 (Multicurrency — Cross Border) 
 

 
 International Swap Dealers Association, Inc. 
 MASTER AGREEMENT 
 dated as of December 23, 2005 
  

					
	Credit Suisse First Boston International	 	and	    	Cheniere LNG Holdings, LLC

 have entered and/or anticipate entering into one or more transactions (each a
“Transaction”) that are or will be governed by this Master Agreement, which includes the schedule (the “Schedule”), and the documents and other confirming evidence (each a “Confirmation”) exchanged between the parties
confirming those Transactions. 
 Accordingly, the parties agree as follows: — 
  

	 	1.	Interpretation 

 (a) Definitions. The
terms defined in Section 14 and in the Schedule will have the meanings therein specified for the purpose of this Master Agreement. 
 (b)
Inconsistency. In the event of any inconsistency between the provisions of the Schedule and the other provisions of this Master Agreement, the Schedule will prevail. In the event of any inconsistency between the provisions of any
Confirmation and this Master Agreement (including the Schedule), such Confirmation will prevail for the purpose of the relevant Transaction. 
 (c) Single Agreement. All Transactions are entered into in reliance on the fact that this Master Agreement and all Confirmations form a single agreement between the parties (collectively referred to as this
“Agreement”), and the parties would not otherwise enter into any Transactions. 
  

	 	2.	Obligations 

 (a) General Conditions.

 (i) Each party will make each payment or delivery specified in each Confirmation to be made by it, subject to the other provisions of this
Agreement. 
 (ii) Payments under this Agreement will be made on the due date for value on that date in the place of the account specified in
the relevant Confirmation or otherwise pursuant to this Agreement, in freely transferable funds and in the manner customary for payments in the required currency. Where settlement is by delivery (that is, other than by payment), such delivery will
be made for receipt on the due date in the manner customary for the relevant obligation unless otherwise specified in the relevant Confirmation or elsewhere in this Agreement. 
 (iii) Each obligation of each party under Section 2(a)(i) is subject to (1) the condition precedent that no Event of Default or Potential Event
of Default with respect to the other party has occurred and is continuing, (2) the condition precedent that no Early Termination Date in respect of the relevant Transaction has occurred or been effectively designated and (3) each other
applicable condition precedent specified in this Agreement. 
  

 Copyright © 1992 by International Swap Dealers Association, Inc. 

 (b) Change of Account. Either party may change its account for receiving a payment or
delivery by giving notice to the other party at least five Local Business Days prior to the scheduled date for the payment or delivery to which such change applies unless such other party gives timely notice of a reasonable objection to such change.

 (c) Netting, If on any date amounts would otherwise be payable:— 
 (i) in the same currency; and 
 (ii) in
respect of the same Transaction, 
 by each party to the other, then, on such date, each party’s obligation to make payment of any such
amount will be automatically satisfied and discharged and, if the aggregate amount that would otherwise have been payable by one party exceeds the aggregate amount that would otherwise have been payable by the other party, replaced by an obligation
upon the party by whom the larger aggregate amount would have been payable to pay to the other party the excess of the larger aggregate amount over the smaller aggregate amount. 
 The parties may elect in respect of two or more Transactions that a net amount will be determined in respect of all amounts payable on the same date in
the same currency in respect of such Transactions, regardless of whether such amounts are payable in respect of the same Transaction. The election may be made in the Schedule or a Confirmation by specifying that subparagraph (ii) above will not
apply to the Transactions identified as being subject to the election, together with the starting date (in which case subparagraph (ii) above will not, or will cease to, apply to such Transactions from such date). This election may be made
separately for different groups of Transactions and will apply separately to each pairing of Offices through which the parties make and receive payments or deliveries. 
 (d) Deduction or Withholding for Tax. 
 (i) Gross-Up. All payments under this Agreement
will be made without any deduction or withholding for or on account of any Tax unless such deduction or withholding is required by any applicable law, as modified by the practice of any relevant governmental revenue authority, then in effect. If a
party is so required to deduct or withhold, then that party (“X”) will:— 
 (1) promptly notify the other party
(“Y”) of such requirement; 
 (2) pay to the relevant authorities the full amount required to be deducted or withheld (including
the full amount required to be deducted or withheld from any additional amount paid by X to Y under this Section 2(d)) promptly upon the earlier of determining that such deduction or withholding is required or receiving notice that such amount
has been assessed against Y; 
 (3) promptly forward to Y an official receipt (or a certified copy), or other documentation reasonably
acceptable to Y, evidencing such payment to such authorities; and 
 (4) if such Tax is an Indemnifiable Tax, pay to Y, in addition to the
payment to which Y is otherwise entitled under this Agreement, such additional amount as is necessary to ensure that the net amount actually received by Y (free and clear of Indemnifiable Taxes, whether assessed against X or Y) will equal the full
amount Y would have received had no such deduction or withholding been required. However, X will not be required to pay any additional amount to Y to the extent that it would not be required to be paid but for:— 
 (A) the failure by Y to comply with or perform any agreement contained in Section 4(a)(i), 4(a)(iii) or 4(d); or 
 (B) the failure of a representation made by Y pursuant to Section 3(f) to be accurate and true unless such failure would not have occurred but for
(I) any action taken by a taxing authority, or brought in a court of competent jurisdiction, on or after the date on which a Transaction is entered into (regardless of whether such action is taken or brought with respect to a party to this
Agreement) or (II) a Change in Tax Law. 
  

					
		  	2	  	ISDA® 1992

 (ii) Liability of:— 
 (1) X is required by any applicable law, as modified by the practice of any relevant governmental revenue authority, to make any deduction or withholding
in respect of which X would not be required to pay an additional amount to Y under Section 2(d)(i)(4); 
 (2) X does not so deduct or
withhold; and 
 (3) a liability resulting from such Tax is assessed directly against X, 
 then, except to the extent Y has satisfied or then satisfies the liability resulting from such Tax, Y will promptly pay to X the amount of such liability
(including any related liability for interest, but including any related liability for penalties only if Y has failed to comply with or perform any agreement contained in Section 4(a)(i), 4(a)(iii) or 4(d)). 
 (e) Default Interest; Other Amounts. Prior to the occurrence or effective designation of an Early Termination Date in respect of the
relevant Transaction, a party that defaults in the performance of any payment obligation will, to the extent permitted by law and subject to Section 6(c), be required to pay interest (before as well as after judgment) on the overdue amount to
the other party on demand in the same currency as such overdue amount, for the period from (and including) the original due date for payment to (but excluding) the date of actual payment, at the Default Rate. Such interest will be calculated on the
basis of daily compounding and the actual number of days elapsed. If, prior to the occurrence or effective designation of an Early Termination Date in respect of the relevant Transaction, a party defaults in the performance of any obligation
required to be settled by delivery, it will compensate the other party on demand if and to the extent provided for in the relevant Confirmation or elsewhere in this Agreement. 
  

	 	3.	Representations 

 Each party represents to the other
party (which representations will be deemed to be repeated by each party on each date on which a Transaction is entered into and, in the case of the representations in Section 3(f), at all times until the termination of this Agreement)
that:— 
 (a) Basic Representations. 
 (i) Status. It is duly organised and validly existing under the laws of the jurisdiction of its organisation or incorporation and, if relevant under such laws, in good standing; 
 (ii) Powers. It has the power to execute this Agreement and any other documentation relating to this Agreement to which it is a party, to
deliver this Agreement and any other documentation relating to this Agreement that it is required by this Agreement to deliver and to perform its obligations under this Agreement and any obligations it has under any Credit Support Document to which
it is a party and has taken all necessary action to authorise such execution, delivery and performance; 
 (iii) No Violation or
Conflict. Such execution, delivery and performance do not violate or conflict with any law applicable to it, any provision of its constitutional documents, any order or judgment of any court or other agency of government applicable to it or
any of its assets or any contractual restriction binding on or affecting it or any of its assets; 
 (iv) Consents. All
governmental and other consents that are required to have been obtained by it with respect to this Agreement or any Credit Support Document to which it is a party have been obtained and are in full force and effect and all conditions of any such
consents have been complied with; and 
 (v) Obligations Binding. Its obligations under this Agreement and any Credit Support
Document to which it is a party constitute its legal, valid and binding obligations, enforceable in accordance with their respective terms (subject to applicable bankruptcy, reorganisation, insolvency, moratorium or similar laws affecting
creditors’ rights generally and subject, as to enforceability, to equitable principles of general application (regardless of whether enforcement is sought in a proceeding in equity or at law)). 
  

					
		  	3	  	ISDA® 1992

 (b) Absence of Certain Events. No Event of Default or Potential Event of Default or, to its
knowledge, Termination Event with respect to it has occurred and is continuing and no such event or circumstance would occur as a result of its entering into or performing its obligations under this Agreement or any Credit Support Document to which
it is a party. 
 (c) Absence of Litigation. There is not pending or, to its knowledge, threatened
against it or any of its Affiliates any action, suit or proceeding at law or in equity or before any court, tribunal, governmental body, agency or official or any arbitrator that is likely to affect the legality, validity or enforceability against
it of this Agreement or any Credit Support Document to which it is a party or its ability to perform its obligations under this Agreement or such Credit Support Document. 
 (d) Accuracy of Specified Information. All applicable information that is furnished in writing by or on behalf of it to the other party and is identified for the purpose of this
Section 3(d) in the Schedule is, as of the date of the information, true, accurate and complete in every material respect. 
 (e)
Payer Tax Representation. Each representation specified in the Schedule as being made by it for the purpose of this Section 3(e) is accurate and true. 
 (f) Payee Tax Representations. Each representation specified in the Schedule as being made by it for the purpose of this Section 3(f) is accurate and true. 
  

	 	4.	Agreements 

 Each party agrees with the other that,
so long as either party has or may have any obligation under this Agreement or under any Credit Support Document to which it is a party:— 
 (a) Furnish Specified Information. It will deliver to the other party or, in certain cases under subparagraph (iii) below, to such government or taxing authority as the other party reasonably directs:—

 (i) any forms, documents or certificates relating to taxation specified in the Schedule or any Confirmation; 
 (ii) any other documents specified in the Schedule or any Confirmation; and 
 (iii) upon reasonable demand by such other party, any form or document that may be required or reasonably requested in writing in order to allow such other party or its Credit Support Provider to make a payment under
this Agreement or any applicable Credit Support Document without any deduction or withholding for or on account of any Tax or with such deduction or withholding at a reduced rate (so long as the completion, execution or submission of such form or
document would not materially prejudice the legal or commercial position of the party in receipt of such demand), with any such form or document to be accurate and completed in a manner reasonably satisfactory to such other party and to be executed
and to be delivered with any reasonably required certification, 
 in each case by the date specified in the Schedule or such Confirmation or,
if none is specified, as soon as reasonably practicable. 
 (b) Maintain Authorisations. It will use all reasonable efforts to
maintain in full force and effect all consents of any governmental or other authority that are required to be obtained by it with respect to this Agreement or any Credit Support Document to which it is a party and will use all reasonable efforts to
obtain any that may become necessary in the future. 
 (c) Comply with Laws. It will comply in all material respects with all
applicable laws and orders to which it may be subject if failure so to comply would materially impair its ability to perform its obligations under this Agreement or any Credit Support Document to which it is a party. 
 (d) Tax Agreement. It will give notice of any failure of a representation made by it under Section 3(f) to be accurate and true
promptly upon learning of such failure. 
 (e) Payment of Stamp Tax. Subject to Section 11, it will pay any Stamp Tax
levied or imposed upon it or in respect of its execution or performance of this Agreement by a jurisdiction in which it is incorporated, 

  

					
		  	4	  	ISDA® 1992

 
organised, managed __ controlled, or considered to have its seat, or in which a branch or office through which it is acting for the purpose of this Agreement
is located (“Stamp Tax Jurisdiction”) and will indemnify the other party against any Stamp Tax levied or imposed upon the other party or in respect of the other party’s execution or performance of this Agreement by any such Stamp Tax
Jurisdiction which is not also a Stamp Tax Jurisdiction with respect to the other party. 
  

	 	5.	Events of Default and Termination Events 

 (a)
Events of Default. The occurrence at any time with respect to a party or, if applicable, any Credit Support Provider of such party or any Specified Entity of such party of any of the following events constitutes an event of default (an
“Event of Default”) with respect to such party:— 
 (i) Failure to Pay or Deliver. Failure by the party to make,
when due, any payment under this Agreement or delivery under Section 2(a)(i) or 2(e) required to be made by it if such failure is not remedied on or before the third Local Business Day after notice of such failure is given to the party;

 (ii) Breach of Agreement. Failure by the party to comply with or perform any agreement or obligation (other than an
obligation to make any payment under this Agreement or delivery under Section 2(a)(i) or 2(e) or to give notice of a Termination Event or any agreement or obligation under Section 4(a)(i), 4(a)(iii) or 4(d)) to be complied with or
performed by the party in accordance with this Agreement if such failure is not remedied on or before the thirtieth day after notice of such failure is given to the party; 
 (iii) Credit Support Default. 
 (1) Failure by the party or any Credit Support Provider of
such party to comply with or perform any agreement or obligation to be complied with or performed by it in accordance with any Credit Support Document if such failure is continuing after any applicable grace period has elapsed; 
 (2) the expiration or termination of such Credit Support Document or the failing or ceasing of such Credit Support Document to be in full force and
effect for the purpose of this Agreement (in either case other than in accordance with its terms) prior to the satisfaction of all obligations of such party under each Transaction to which such Credit Support Document relates without the written
consent of the other party; or 
 (3) the party or such Credit Support Provider disaffirms, disclaims, repudiates or rejects, in whole or in
part, or challenges the validity of, such Credit Support Document; 
 (iv) Misrepresentation. A representation (other than a
representation under Section 3(e) or (f)) made or repeated or deemed to have been made or repeated by the party or any Credit Support Provider of such party in this Agreement or any Credit Support Document proves to have been incorrect or
misleading in any material respect when made or repeated or deemed to have been made or repeated; 
 (v) Default under Specified
Transaction. The party, any Credit Support Provider of such party or any applicable Specified Entity of such party (1) defaults under a Specified Transaction and, after giving effect, to any applicable notice requirement or grace
period, there occurs a liquidation of, an acceleration of obligations under, or an early termination of, that Specified Transaction, (2) defaults, after giving effect to any applicable notice requirement or grace period, in making any payment
or delivery due on the last payment, delivery or exchange date of, or any payment on early termination of, a Specified Transaction (or such default continues for at least three Local Business Days if there is no applicable notice requirement or
grace period) or (3) disaffirms, disclaims, repudiates or rejects, in whole or in part, a Specified Transaction (or such action is taken by any person or entity appointed or empowered to operate it or act on its behalf); 
 (vi) Cross Default. If “Cross Default” is specified in the Schedule as applying to the party, the occurrence or existence of
(1) a default, event of default or other similar condition or event (however 

  

					
		  	5	  	ISDA® 1992

 
described) in respect of such party, any Credit Support Provider of such party or any applicable Specified Entity of such party under one or more agreements
or instruments relating to Specified Indebtedness of any of them (individually or collectively) in an aggregate amount of not less than the applicable Threshold Amount (as specified in the Schedule) which has resulted in such Specified Indebtedness
becoming, or becoming capable at such time of being declared, due and payable under such agreements or instruments, before it would otherwise have been due and payable or (2) a default by such party, such Credit Support Provider or such
Specified Entity (individually or collectively) in making one or more payments on the due date thereof in an aggregate amount of not less than the applicable Threshold Amount under such agreements or instruments (after giving effect to any
applicable notice requirement or grace period); 
 (vii) Bankruptcy. The party, any Credit Support Provider of
such party or any applicable Specified Entity of such party: — 
 (1) is dissolved (other than pursuant to a consolidation, amalgamation
or merger); (2) becomes insolvent or is unable to pay its debts or fails or admits in writing its inability generally to pay its debts as they become due; (3) makes a general assignment, arrangement or composition with or for the benefit
of its creditors; (4) institutes or has instituted against it a proceeding seeking a judgment of insolvency or bankruptcy or any other relief under any bankruptcy or insolvency law or other similar law affecting creditors’ rights, or a
petition is presented for its winding-up or liquidation, and, in the case of any such proceeding or petition instituted or presented against it, such proceeding or petition (A) results in a judgment of insolvency or bankruptcy or the entry of
an order for relief or the making of an order for its winding-up or liquidation or (B) is not dismissed, discharged, stayed or restrained in each case within 30 days of the institution or presentation thereof; (5) has a resolution passed
for its winding-up, official management or liquidation (other than pursuant to a consolidation, amalgamation or merger); (6) seeks or becomes subject to the appointment of an administrator, provisional liquidator, conservator, receiver,
trustee, custodian or other similar official for it or for all or substantially all its assets; (7) has a secured party take possession of all or substantially all its assets or has a distress, execution, attachment, sequestration or other
legal process levied, enforced or sued on or against all or substantially all its assets and such secured party maintains possession, or any such process is not dismissed, discharged, stayed or restrained, in each case within 30 days thereafter;
(8) causes or is subject to any event with respect to it which, under the applicable laws of any jurisdiction, has an analogous effect to any of the events specified in clauses (1) to (7) (inclusive); or (9) takes any action in
furtherance of, or indicating its consent to, approval of, or acquiescence in, any of the foregoing acts; or 
 (viii) Merger
Without Assumption. The party or any Credit Support Provider of such party consolidates or amalgamates with, or merges with or into, or transfers all or substantially all its assets to, another entity and, at the time of such
consolidation, amalgamation, merger or transfer: — 
 (1) the resulting, surviving or transferee entity fails to assume all the
obligations of such party or such Credit Support Provider under this Agreement or any Credit Support Document to which it or its predecessor was a party by operation of law or pursuant to an agreement reasonably satisfactory to the other party to
this Agreement; or 
 (2) the benefits of any Credit Support Document fail to extend (without the consent of the other party) to the
performance by such resulting, surviving or transferee entity of its obligations under this Agreement. 
 (b) Termination
Events. The occurrence at any time with respect to a party or, if applicable, any Credit Support Provider of such party or any Specified Entity of such party of any event specified below constitutes an Illegality if the event is
specified in (i) below, a Tax Event if the event is specified in (ii) below or a Tax Event Upon Merger if the event is specified in (iii) below, and, if specified to be applicable, a Credit Event 

  

					
		  	6	  	ISDA® 1992

 
Upon Merger if the event is specified pursuant to (iv) below or an Additional Termination Event if the event is specified pursuant to
(v) below:— 
 (i) Illegality. Due to the adoption of, or any change in, any applicable law after the date on which a
Transaction is entered into, or due to the promulgation of, or any change in, the interpretation by any court, tribunal or regulatory authority with competent jurisdiction of any applicable law after such date, it becomes unlawful (other than as a
result of a breach by the party of Section 4(b)) for such party (which will be the Affected Party): — 
 (1) to perform any
absolute or contingent obligation to make a payment or delivery or to receive a payment or delivery in respect of such Transaction or to comply with any other material provision of this Agreement relating to such Transaction; or 
 (2) to perform, or for any Credit Support Provider of such party to perform, any contingent or other obligation which the party (or such Credit Support
Provider) has under any Credit Support Document relating to such Transaction; 
 (ii) Tax Event. Due to (x) any action
taken by a taxing authority, or brought in a court of competent jurisdiction, on or after the date on which a Transaction is entered into (regardless of whether such action is taken or brought with respect to a party to this Agreement) or (y) a
Change in Tax Law, the party (which will be the Affected Party) will, or there is a substantial likelihood that it will, on the next succeeding Scheduled Payment Date (1) be required to pay to the other party an additional amount in respect of
an Indemnifiable Tax under Section 2(d)(i)(4) (except in respect of interest under Section 2(e), 6(d)(ii) or 6(e)) or (2) receive a payment from which an amount is required to be deducted or withheld for or on account of a Tax (except
in respect of interest under Section 2(e), 6(d)(ii) or 6(e)) and no additional amount is required to be paid in respect of such Tax under Section 2(d)(i)(4) (other than by reason of Section 2(d)(i)(4)(A) or (B)); 
 (iii) Tax Event Upon Merger. The party (the “Burdened Party”) on the next succeeding Scheduled Payment Date will either
(1) be required to pay an additional amount in respect of an Indemnifiable Tax under Section 2(d)(i)(4) (except in respect of interest under Section 2(e), 6(d)(ii) or 6(e)) or (2) receive a payment from which an amount has been
deducted or withheld for or on account of any Indemnifiable Tax in respect of which the other party is not required to pay an additional amount (other than by reason of Section 2(d)(i)(4)(A) or (B)), in either case as a result of a party
consolidating or amalgamating with, or merging with or into, or transferring all or substantially all its assets to, another entity (which will be the Affected Party) where such action does not constitute an event described in
Section 5(a)(viii); 
 (iv) Credit Event Upon Merger. If “Credit Event Upon Merger” is specified in the Schedule
as applying to the party, such party (“X”), any Credit Support Provider of X or any applicable Specified Entity of X consolidates or amalgamates with, or merges with or into, or transfers all or substantially all its assets to, another
entity and such action does not constitute an event described in Section 5(a)(viii) but the creditworthiness of the resulting, surviving or transferee entity is materially weaker than that of X, such Credit Support Provider or such Specified
Entity, as the case may be, immediately prior to such action (and, in such event, X or its successor or transferee, as appropriate, will be the Affected Party); or 
 (v) Additional Termination Event. If any “Additional Termination Event” is specified in the Schedule or any Confirmation as applying, the occurrence of such event (and, in such event, the
Affected Party or Affected Parties shall be as specified for such Additional Termination Event in the Schedule or such Confirmation). 
 (c)
Event of Default and Illegality. If an event or circumstance which would otherwise constitute or give rise to an Event of Default also constitutes an Illegality, it will be treated as an Illegality and will not constitute an Event of
Default. 
  

					
		  	7	  	ISDA® 1992

	 	6.	Early Termination 

 (a) Right to Terminate
Following Event of Default. If at any time an Event of Default with respect to a party (the “Defaulting Party”) has occurred and is then continuing, the other party (the “Non-defaulting Party”) may, by not more than 20 days notice to the Defaulting Party specifying the relevant Event of Default, designate a day not earlier
than the day such notice is effective as an Early Termination Date in respect of all outstanding Transactions. If, however, “Automatic Early Termination” is specified in the Schedule as applying to a party, then an Early Termination Date
in respect of all outstanding Transactions will occur immediately upon the occurrence with respect to such party of an Event of Default specified in Section 5(a)(vii)(l), (3), (5), (6) or, to the extent analogous thereto, (8), and as of
the time immediately preceding the institution of the relevant proceeding or the presentation of the relevant petition upon the occurrence with respect to such party of an Event of Default specified in Section 5(a)(vii)(4) or, to the extent
analogous thereto, (8). 
 (b) Right to Terminate Following Termination Event. 
 (i) Notice. If a Termination Event occurs, an Affected Party will, promptly upon becoming aware of it, notify the other party, specifying
the nature of that Termination Event and each Affected Transaction and will also give such other information about that Termination Event as the other party may reasonably require. 
 (ii) Transfer to Avoid Termination Event. If either an Illegality under Section 5(b)(i)(l) or a Tax Event occurs and there is only one
Affected Party, or if a Tax Event Upon Merger occurs and the Burdened Party is the Affected Party, the Affected Party will, as a condition to its right to designate an Early Termination Date under Section 6(b)(iv), use all reasonable efforts
(which will not require such party to incur a loss, excluding immaterial, incidental expenses) to transfer within 20 days after it gives notice under Section 6(b)(i) all its rights and obligations under this Agreement in respect of the Affected
Transactions to another of its Offices or Affiliates so that such Termination Event ceases to exist. 
 If the Affected Party is not able to
make such a transfer it will give notice to the other party to that effect within such 20 day period, whereupon the other party may effect such a transfer within 30 days after the notice is given under Section 6(b)(i). 
 Any such transfer by a party under this Section 6(b)(ii) will be subject to and conditional upon the prior written consent of the other party, which
consent will not be withheld if such other party’s policies in effect at such time would permit it to enter into transactions with the transferee on the terms proposed. 
 (iii) Two Affected Parties. If an Illegality under Section 5(b)(i)(l) or a Tax Event occurs and there are two Affected Parties, each
party will use all reasonable efforts to reach agreement within 30 days after notice thereof is given under Section 6(b)(i) on action to avoid that Termination Event. 
 (iv) Right to Terminate. If: — 
 (1) a transfer under Section 6(b)(ii) or an
agreement under Section 6(b)(iii), as the case may be, has not been effected with respect to all Affected Transactions within 30 days after an Affected Party gives notice under Section 6(b)(i); or 
 (2) an Illegality under Section 5(b)(i)(2), a Credit Event Upon Merger or an Additional Termination Event occurs, or a Tax Event Upon Merger occurs
and the Burdened Party is not the Affected Party, 
 either party in the case of an Illegality, the Burdened Party in the case of a Tax Event
Upon Merger, any Affected Party in the case of a Tax Event or an Additional Termination Event if there is more than one Affected Party, or the party which is not the Affected Party in the case of a Credit Event Upon Merger or an Additional
Termination Event if there is only one Affected Party may, by not more than 20 days notice to the other party and provided that the relevant Termination Event is then 

  

					
		  	8	  	ISDA® 1992

 
continuing, designate a day not earlier than the day such notice is effective as an Early Termination Date in respect of all Affected Transactions.

 (c)
Effect of Designation. 
 (i) If notice designating an Early Termination Date is given under Section 6(a) or (b), the Early
Termination Date will occur on the date so designated, whether or not the relevant Event of Default or Termination Event is then continuing. 
 (ii) Upon the occurrence or effective designation of an Early Termination Date, no further payments or deliveries under Section 2(a)(i) or 2(e) in respect of the Terminated Transactions will be required to be made, but without
prejudice to the other provisions of this Agreement. The amount, if any, payable in respect of an Early Termination Date shall be determined pursuant to Section 6(e). 
 (d) Calculations. 
 (i) Statement. On or as soon as reasonably practicable
following the occurrence of an Early Termination Date, each party will make the calculations on its part, if any, contemplated by Section 6(e) and will provide to the other party a statement (1) showing, in reasonable detail, such
calculations (including all relevant quotations and specifying any amount payable under Section 6(e)) and (2) giving details of the relevant account to which any amount payable to it is to be paid. In the absence of written confirmation
from the source of a quotation obtained in determining a Market Quotation, the records of the party obtaining such quotation will be conclusive evidence of the existence and accuracy of such quotation. 
 (ii) Payment Date. An amount calculated as being due in respect of any Early Termination Date under Section 6(e) will be payable on the
day that notice of the amount payable is effective (in the case of an Early Termination Date which is designated or occurs as a result of an Event of Default) and on the day which is two Local Business Days after the day on which notice of the
amount payable is effective (in the case of an Early Termination Date which is designated as a result of a Termination Event). Such amount will be paid together with (to the extent permitted under applicable law) interest thereon (before as well as
after judgment) in the Termination Currency, from (and including) the relevant Early Termination Date to (but excluding) the date such amount is paid, at the Applicable Rate. Such interest will be calculated on the basis of daily compounding and the
actual number of days elapsed. 
 (e) Payments on Early Termination. If an Early Termination Date occurs, the following
provisions shall apply based on the parties’ election in the Schedule of a payment measure, either “Market Quotation” or “Loss”, and a payment method, either the “First Method” or the “Second Method”. If
the parties fail to designate a payment measure or payment method in the Schedule, it will be deemed that “Market Quotation” or the “Second Method”, as the case may be, shall apply. The amount, if any, payable in respect of an
Early Termination Date and determined pursuant to this Section will be subject to any Set-off. 
 (i) Events of Default. If the
Early Termination Date results from an Event of Default: — 
 (1) First Method and Market Quotation. If the First Method
and Market Quotation apply, the Defaulting Party will pay to the Non-defaulting Party the excess, if a positive number, of (A) the sum of the Settlement Amount (determined by the Non-defaulting Party) in respect of the Terminated Transactions
and the Termination Currency Equivalent of the Unpaid Amounts owing to the Non-defaulting Party over (B) the Termination Currency Equivalent of the Unpaid Amounts owing to the Defaulting Party. 
 (2) First Method and Loss. If the First Method and Loss apply, the Defaulting Party will pay to the Non-defaulting Party, if
a positive number, the Non-defaulting Party’s Loss in respect of this Agreement. 
 (3) Second Method and Market
Quotation. If the Second Method and Market Quotation apply, an amount will be payable equal to (A) the sum of the Settlement Amount (determined by the 

  

					
		  	9	  	ISDA® 1992

 
Non-defaulting Party) in respect of the Terminated Transactions and the Termination Currency Equivalent of the Unpaid Amounts owing to the Non-defaulting
Party less (B) the Termination Currency Equivalent of the Unpaid Amounts owing to the Defaulting Party. If that amount is a positive number, the Defaulting Party will pay it to the Non-defaulting Party; if it is a negative number, the
Non-defaulting Party will pay the absolute value of that amount to the Defaulting Party. 
 (4) Second Method and Loss. If the
Second Method and Loss apply, an amount will be payable equal to the Non-defaulting Party’s Loss in respect of this Agreement. If that amount is a positive number, the Defaulting Party will pay it to the Non-defaulting Party; if it is a
negative number, the Non-defaulting Party will pay the absolute value of that amount to the Defaulting Party. 
 (ii) Termination
Events. If the Early Termination Date results from a Termination Event: — 
 (1) One Affected Party. If there
is one Affected Party, the amount payable will be determined in accordance with Section 6(e)(i)(3), if Market Quotation applies, or Section 6(e)(i)(4), if Loss applies, except that, in either case, references to the Defaulting Party and to
the Non-defaulting Party will be deemed to be references to the Affected Party and the party which is not the Affected Party, respectively, and, if Loss applies and fewer than all the Transactions are being terminated, Loss shall be calculated in
respect of all Terminated Transactions. 
 (2) Two Affected Parties. If there are two Affected Parties: — 
 (A) if Market Quotation applies, each party will determine a Settlement Amount in respect of the Terminated Transactions, and an amount will be payable
equal to (I) the sum of (a) one-half of the difference between the Settlement Amount of the party with the higher Settlement Amount (“X”) and the Settlement Amount of the party with the lower Settlement Amount (“Y”) and
(b) the Termination Currency Equivalent of the Unpaid Amounts owing to X less (II) the Termination Currency Equivalent of the Unpaid Amounts owing to Y; and 
 (B) if Loss applies, each party will determine its Loss in respect of this Agreement (or, if fewer than all the Transactions are being terminated, in respect of all Terminated Transactions) and an amount will be
payable equal to one-half of the difference between the Loss of the party with the higher Loss (“X”) and the Loss of the party with the lower Loss (“Y”). 
 If the amount payable is a positive number, Y will pay it to X; if it is a negative number, X will pay the absolute value of that amount to Y.

 (iii) Adjustment for Bankruptcy. In circumstances where an Early Termination Date occurs because “Automatic Early
Termination” applies in respect of a party, the amount determined under this Section 6(e) will be subject to such adjustments as are appropriate and permitted by law to reflect any payments or deliveries made by one party to the other
under this Agreement (and retained by such other party) during the period from the relevant Early Termination Date to the date for payment determined under Section 6(d)(ii). 
 (iv) Pre-Estimate. The parties agree that if Market Quotation applies an amount recoverable under this Section 6(e) is a reasonable
pre-estimate of loss and not a penalty. Such amount is payable for the loss of bargain and the loss of protection against future risks and except as otherwise provided in this Agreement neither party will be entitled to recover any additional
damages as a consequence of such losses. 
  

					
		  	10	  	ISDA® 1992

	 	7.	Transfer 

 Subject to Section 6(b)(ii), neither
this Agreement nor any interest or obligation in or under this Agreement may be transferred (whether by way of security or otherwise) by either party without the prior written consent of the other party, except that: — 
 (a) a party may make such a transfer of this Agreement pursuant to a consolidation or amalgamation with, or merger with or into, or transfer of all or
substantially all its assets to, another entity (but without prejudice to any other right or remedy under this Agreement); and 
 (b) a party
may make such a transfer of all or any part of its interest in any amount payable to it from a Defaulting Party under Section 6(e). 
 Any purported transfer that is not in compliance with this Section will be void. 
  

	 	8.	Contractual Currency 

 (a) Payment in the
Contractual Currency. Each payment under this Agreement will be made in the relevant currency specified in this Agreement for that payment (the “Contractual Currency”). To the extent permitted by applicable law, any obligation to
make payments under this Agreement in the Contractual Currency will not be discharged or satisfied by any tender in any currency other than the Contractual Currency, except to the extent such tender results in the actual receipt by the party to
which payment is owed, acting in a reasonable manner and in good faith in converting the currency so tendered into the Contractual Currency, of the full amount in the Contractual Currency of all amounts payable in respect of this Agreement. If for
any reason the amount in the Contractual Currency so received falls short of the amount in the Contractual Currency payable in respect of this Agreement, the party required to make the payment will, to the extent permitted by applicable law,
immediately pay such additional amount in the Contractual Currency as may be necessary to compensate for the shortfall. If for any reason the amount in the Contractual Currency so received exceeds the amount in the Contractual Currency payable in
respect of this Agreement, the party receiving the payment will refund promptly the amount of such excess. 
 (b) Judgments. To
the extent permitted by applicable law, if any judgment or order expressed in a currency other than the Contractual Currency is rendered (i) for the payment of any amount owing in respect of this Agreement, (ii) for the payment of any
amount relating to any early termination in respect of this Agreement or (iii) in respect of a judgment or order of another court for the payment of any amount described in (i) or (ii) above, the party seeking recovery, after recovery
in full of the aggregate amount to which such party is entitled pursuant to the judgment or order, will be entitled to receive immediately from the other party the amount of any shortfall of the Contractual Currency received by such party as a
consequence of sums paid in such other currency and will refund promptly to the other party any excess of the Contractual Currency received by such party as a consequence of sums paid in such other currency if such shortfall or such excess arises or
results from any variation between the rate of exchange at which the Contractual Currency is converted into the currency of the judgment or order for the purposes of such judgment or order and the rate of exchange at which such party is able, acting
in a reasonable manner and in good faith in converting the currency received into the Contractual Currency, to purchase the Contractual Currency with the amount of the currency of the judgment or order actually received by such party. The term
“rate of exchange” includes, without limitation, any premiums and costs of exchange payable in connection with the purchase of or conversion into the Contractual Currency. 
 (c) Separate Indemnities. To the extent permitted by applicable law, these indemnities constitute separate and independent obligations from
the other obligations in this Agreement, will be enforceable as separate and independent causes of action, will apply notwithstanding any indulgence granted by the party to which any payment is owed and will not be affected by judgment being
obtained or claim or proof being made for any other sums payable in respect of this Agreement. 
 (d) Evidence of Loss. For the
purpose of this Section 8, it will be sufficient for a party to demonstrate that it would have suffered a loss had an actual exchange or purchase been made. 
  

					
		  	11	  	ISDA® 1992

	 	9.	Miscellaneous 

 (a) Entire Agreement.
This Agreement constitutes the entire agreement and understanding of the parties with respect to its subject matter and supersedes all oral communication and prior writings with respect thereto. 
 (b) Amendments. No amendment, modification or waiver in respect of this Agreement will be effective unless in writing (including a writing
evidenced by a facsimile transmission) and executed by each of the parties or confirmed by an exchange of telexes or electronic messages on an electronic messaging system. 
 (c) Survival of Obligations. Without prejudice to Sections 2(a)(iii) and 6(c)(ii), the obligations of the parties under this Agreement will survive the termination of any Transaction. 
 (d) Remedies Cumulative. Except as provided in this Agreement, the rights, powers, remedies and privileges provided in this Agreement are
cumulative and not exclusive of any rights, powers, remedies and privileges provided by law. 
 (e) Counterparts and
Confirmations. 
 (i) This Agreement (and each amendment, modification and waiver in respect of it) may be executed and delivered in
counterparts (including by facsimile transmission), each of which will be deemed an original. 
 (ii) The parties intend that they are legally
bound by the terms of each Transaction from the moment they agree to those terms (whether orally or otherwise). A Confirmation shall be entered into as soon as practicable and may be executed and delivered in counterparts (including by facsimile
transmission) or be created by an exchange of telexes or by an exchange of electronic messages on an electronic messaging system, which in each case will be sufficient for all purposes to evidence a binding supplement to this Agreement. The parties
will specify therein or through another effective means that any such counterpart, telex or electronic message constitutes a Confirmation. 
 (f) No Waiver of Rights. A failure or delay in exercising any right, power or privilege in respect of this Agreement will not be presumed to operate as a waiver, and a single or partial exercise of any right, power or
privilege will not be presumed to preclude any subsequent or further exercise, of that right, power or privilege or the exercise of any other right, power or privilege. 
 (g) Headings. The headings used in this Agreement are for convenience of reference only and are not to affect the construction of or to be taken into consideration in interpreting this Agreement.

  

	 	10.	Offices; Multibranch Parties 

 (a) If
Section 10(a) is specified in the Schedule as applying, each party that enters into a Transaction through an Office other than its head or home office represents to the other party that, notwithstanding the place of booking office or
jurisdiction of incorporation or organisation of such party, the obligations of such party are the same as if it had entered into the Transaction through its head or home office. This representation will be deemed to be repeated by such party on
each date on which a Transaction is entered into. 
 (b) Neither party may change the Office through which it makes and receives payments or
deliveries for the purpose of a Transaction without the prior written consent of the other party. 
 (c) If a party is specified as a
Multibranch Party in the Schedule, such Multibranch Party may make and receive payments or deliveries under any Transaction through any Office listed in the Schedule, and the Office through which it makes and receives payments or deliveries with
respect to a Transaction will be specified in the relevant Confirmation. 
  

	 	11.	Expenses 

 A Defaulting Party will, on demand,
indemnify and hold harmless the other party for and against all reasonable out-of-pocket expenses, including legal fees and Stamp Tax, incurred by such other party by reason of the enforcement and protection of its rights under this Agreement or any
Credit Support Document 

  

					
		  	12	  	ISDA® 1992

 
to which the Defaulting Party is a party or by reason of the early termination of any Transaction, including, but not limited to, costs of collection.

  

	 	12.	Notices 

 (a) Effectiveness. Any
notice or other communication in respect of this Agreement may be given in any manner set forth below (except that a notice or other communication under Section 5 or 6 may not be given by facsimile transmission or electronic messaging system)
to the address or number or in accordance with the electronic messaging system details provided (see the Schedule) and will be deemed effective as indicated:— 
 (i) if in writing and delivered in person or by courier, on the date it is delivered; 
 (ii) if sent by
telex, on the date the recipient’s answerback is received; 
 (iii) if sent by facsimile transmission, on the date that transmission is
received by a responsible employee of the recipient in legible form (it being agreed that the burden of proving receipt will be on the sender and will not be met by a transmission report generated by the sender’s facsimile machine); 

(iv) if sent by certified or registered mail (airmail, if overseas) or the equivalent (return receipt requested), on the date that mail is delivered or
its delivery is attempted; or 
 (v) if sent by electronic messaging system, on the date that electronic message is received, 
 unless the date of that delivery (or attempted delivery) or that receipt, as applicable, is not a Local Business Day or that communication is delivered
(or attempted) or received, as applicable, after the close of business on a Local Business Day, in which case that communication shall be deemed given and effective on the first following day that is a Local Business Day. 
 (b) Change of Addresses. Either party may by notice to the other change the address, telex or facsimile number or electronic
messaging system details at which notices or other communications are to be given to it. 
  

	 	13.	Governing Law and Jurisdiction 

 (a)
Governing Law. This Agreement will be governed by and construed in accordance with the law specified in the Schedule. 
 (b) Jurisdiction. With respect to any suit, action or proceedings relating to this Agreement (“Proceedings”), each party irrevocably:— 
 (i) submits to the jurisdiction of the English courts, if this Agreement is expressed to be governed by English law, or to the non-exclusive jurisdiction
of the courts of the State of New York and the United States District Court located in the Borough of Manhattan in New York City, if this Agreement is expressed to be governed by the laws of the State of New York; and 
 (ii) waives any objection which it may have at any time to the laying of venue of any Proceedings brought in any such court, waives any claim that such
Proceedings have been brought in an inconvenient forum and further waives the right to object, with respect to such Proceedings, that such court does not have any jurisdiction over such party. 
 Nothing in this Agreement precludes either party from bringing Proceedings in any other jurisdiction (outside, if this Agreement is expressed to be
governed by English law, the Contracting States, as defined in Section 1(3) of the Civil Jurisdiction and Judgments Act 1982 or any modification, extension or re-enactment thereof for the time being in force) nor will the bringing of
Proceedings in any one or more jurisdictions preclude the bringing of Proceedings in any other jurisdiction. 
 (c) Service of
Process. Each party irrevocably appoints the Process Agent (if any) specified opposite its name in the Schedule to receive, for it and on its behalf, service of process in any Proceedings. If for any 

  

					
		  	13	  	ISDA® 1992

 
reason any party’s Process Agent is unable to act as such, such party will promptly notify the other party and within 30 days appoint a substitute
process agent acceptable to the other party. The parties irrevocably consent to service of process given in the manner provided for notices in Section 12. Nothing in this Agreement will affect the right of either party to serve process in any
other manner permitted by law. 
 (d) Waiver of Immunities. Each party irrevocably waives, to the fullest extent permitted by
applicable law, with respect to itself and its revenues and assets (irrespective of their use or intended use), all immunity on the grounds of sovereignty or other similar grounds from (i) suit, (ii) jurisdiction of any court,
(iii) relief by way of injunction, order for specific performance or for recovery of property, (iv) attachment of its assets. (whether before or after judgment) and (v) execution or enforcement of any judgment to which it or its
revenues or assets might otherwise be entitled in any Proceedings in the courts of any jurisdiction and irrevocably agrees, to the extent permitted by applicable law, that it will not claim any such immunity in any Proceedings. 
  

	 	14.	Definitions 

 As used in this Agreement:—

 “Additional Termination Event” has the meaning specified in Section 5(b). 
 “Affected Party” has the meaning specified in Section 5(b). 
 “Affected Transactions” means (a) with respect to any Termination Event consisting of an Illegality, Tax Event or Tax Event
Upon Merger, all Transactions affected by the occurrence of such Termination Event and (b) with respect to any other Termination Event, all Transactions. 
 “Affiliate” means, subject to the Schedule, in relation to any person, any entity controlled, directly or indirectly, by the person, any entity that controls, directly or indirectly, the person
or any entity directly or indirectly under common control with the person. For this purpose, “control” of any entity or person means ownership of a majority of the voting power of the entity or person. 
 “Applicable Rate” means:— 
 (a) in respect of obligations payable or deliverable (or which would have been but for Section 2(a)(iii)) by a Defaulting Party, the Default Rate; 
 (b) in respect of an obligation to pay an amount under Section 6(e) of either party from and after the date (determined in accordance with
Section 6(d)(ii)) on which that amount is payable, the Default Rate; 
 (c) in respect of all other obligations payable or deliverable
(or which would have been but for Section 2(a)(iii)) by a Non-defaulting Party, the Non-default Rate; and 
 (d) in all other cases, the
Termination Rate.  
 “Burdened Party” has the meaning specified in Section 5(b). 
 “Change in Tax Law” means the enactment, promulgation, execution or ratification of, or any change in or amendment to, any law (or
in the application or official interpretation of any law) that occurs on or after the date on which the relevant Transaction is entered into. 
 “consent” includes a consent, approval, action, authorisation, exemption, notice, filing, registration or exchange control consent. 
 “Credit Event Upon Merger” has the meaning specified in Section 5(b). 
 “Credit Support Document” means any agreement or instrument that is specified as such in this Agreement. 
 “Credit Support Provider” has the meaning specified in the Schedule. 
 “Default
Rate” means a rate per annum equal to the cost (without proof or evidence of any actual cost) to the relevant payee (as certified by it) if it were to fund or of funding the relevant amount plus 1% per annum. 
  

					
		  	14	  	ISDA® 1992

 “Defaulting Party” has the meaning specified in Section 6(a). 
 “Early Termination Date” means the date determined in accordance with Section 6(a) or 6(b)(iv). 
 “Event of Default” has the meaning specified in Section 5(a) and, if applicable, in the Schedule.  

“Illegality” has the meaning specified in Section 5(b). 
 “Indemnifiable Tax” means any Tax other than a Tax that would not be imposed in respect of a payment under this Agreement but for
a present or former connection between the jurisdiction of the government or taxation authority imposing such Tax and the recipient of such payment or a person related to such recipient (including, without limitation, a connection arising from such
recipient or related person being or having been a citizen or resident of such jurisdiction, or being or having been organised, present or engaged in a trade or business in such jurisdiction, or having or having had a permanent establishment or
fixed place of business in such jurisdiction, but excluding a connection arising solely from such recipient or related person having executed, delivered, performed its obligations or received a payment under, or enforced, this Agreement or a Credit
Support Document). 
 “law” includes any treaty, law, rule or regulation (as modified, in the case of tax matters, by
the practice of any relevant governmental revenue authority) and “lawful” and “unlawful” will be construed accordingly. 
 “Local Business Day” means, subject to the Schedule, a day on which commercial banks are open for business (including dealings in foreign exchange and foreign currency deposits) (a) in
relation to any obligation under Section 2(a)(i), in the place(s) specified in the relevant Confirmation or, if not so specified, as otherwise agreed by the parties in writing or determined pursuant to provisions contained, or incorporated by
reference, in this Agreement, (b) in relation to any other payment, in the place where the relevant account is located and, if different, in the principal financial centre, if any, of the currency of such payment, (c) in relation to any
notice or other communication, including notice contemplated under Section 5(a)(i), in the city specified in the address for notice provided by the recipient and, in the case of a notice contemplated by Section 2(b), in the place where the
relevant new account is to be located and (d) in relation to Section 5(a)(v)(2), in the relevant locations for performance with respect to such Specified Transaction. 
 “Loss” means, with respect to this Agreement or one or more Terminated Transactions, as the case may be, and a party, the
Termination Currency Equivalent of an amount that party reasonably determines in good faith to be its total losses and costs (or gain, in which case expressed as a negative number) in connection with this Agreement or that Terminated Transaction or
group of Terminated Transactions, as the case may be, including any loss of bargain, cost of funding or, at the election of such party but without duplication, loss or cost incurred as a result of its terminating, liquidating, obtaining or
reestablishing any hedge or related trading position (or any gain resulting from any of them). Loss includes losses and costs (or gains) in respect of any payment or delivery required to have been made (assuming satisfaction of each applicable
condition precedent) on or before the relevant Early Termination Date and not made, except, so as to avoid duplication, if Section 6(e)(i)(1) or (3) or 6(e)(ii)(2)(A) applies. Loss does not include a party’s legal fees and
out-of-pocket expenses referred to under Section 11. A party will determine its Loss as of the relevant Early Termination Date, or, if that is not reasonably practicable, as of the earliest date thereafter as is reasonably practicable. A party
may (but need not) determine its Loss by reference to quotations of relevant rates or prices from one or more leading dealers in the relevant markets. 
 “Market Quotation” means, with respect to one or more Terminated Transactions and a party making the determination, an amount determined on the basis of quotations from Reference Market-makers.
Each quotation will be for an amount, if any, that would be paid to such party (expressed as a negative number) or by such party (expressed as a positive number) in consideration of an agreement between such party (taking into account any existing
Credit Support Document with respect to the obligations of such party) and the quoting Reference Market-maker to enter into a transaction (the “Replacement Transaction”) that would have the effect of preserving for such party the economic
equivalent of any payment or delivery (whether the underlying obligation was absolute or contingent and assuming the satisfaction of each applicable condition precedent) by the parties under Section 2(a)(i) in respect of such Terminated
Transaction or group of Terminated Transactions that would, but for the occurrence of the relevant Early Termination Date, have 

  

					
		  	15	  	ISDA® 1992

 
been required after that date. For this purpose, Unpaid Amounts in respect of the Terminated Transaction or group of Terminated Transactions are to be
excluded but, without limitation, any payment or delivery that would, but for the relevant Early Termination Date, have been required (assuming satisfaction of each applicable condition precedent) after that Early Termination Date is to be included.
The Replacement Transaction would be subject to such documentation as such party and the Reference Market-maker may, in good faith, agree. The party making the determination (or its agent) will request each Reference Market-maker to provide its
quotation to the extent reasonably practicable as of the same day and time (without regard to different time zones) on or as soon as reasonably practicable after the relevant Early Termination Date. The day and time as of which those quotations are
to be obtained will be selected in good faith by the party obliged to make a determination under Section 6(e), and, if each party is so obliged, after consultation with the other. If more than three quotations are provided, the Market Quotation
will be the arithmetic mean of the quotations, without regard to the quotations having the highest and lowest values. If exactly three such quotations are provided, the Market Quotation will be the quotation remaining after disregarding the highest
and lowest quotations. For this purpose, if more than one quotation has the same highest value or lowest value, then one of such quotations shall be disregarded. If fewer than three quotations are provided, it will be deemed that the Market
Quotation in respect of such Terminated Transaction or group of Terminated Transactions cannot be determined. 
 “Non-default
Rate” means a rate per annum equal to the cost (without proof or evidence of any actual cost) to the Non-defaulting Party (as certified by it) if it were to fund the relevant amount. 
 “Non-defaulting Party” has the meaning specified in Section 6(a). 
 “Office” means a branch or office of a party, which may be such party’s head or home office. 
 “Potential Event of Default” means any event which, with the giving of notice or the lapse of time or both, would constitute an
Event of Default. 
 “Reference Market-makers” means four leading dealers in the relevant market selected by the party
determining a Market Quotation in good faith (a) from among dealers of the highest credit standing which satisfy all the criteria that such party applies generally at the time in deciding whether to offer or to make an extension of credit and
(b) to the extent practicable, from among such dealers having an office in the same city. 
 “Relevant
Jurisdiction” means, with respect to a party, the jurisdictions (a) in which the party is incorporated, organised, managed and controlled or considered to have its seat, (b) where an Office through which the party is acting
for purposes of this Agreement is located, (c) in which the party executes this Agreement and (d) in relation to any payment, from or through which such payment is made. 
 “Scheduled Payment Date” means a date on which a payment or delivery is to be made under Section 2(a)(i) with respect to a
Transaction. 
 “Set-off” means set-off, offset, combination of accounts, right of retention or withholding or similar
right or requirement to which the payer of an amount under Section 6 is entitled or subject (whether arising under this Agreement, another contract, applicable law or otherwise) that is exercised by, or imposed on, such payer. 
 “Settlement Amount” means, with respect to a party and any Early Termination Date, the sum of: — 
 (a) the Termination Currency Equivalent of the Market Quotations (whether positive or negative) for each Terminated Transaction or group of Terminated
Transactions for which a Market Quotation is determined; and 
 (b) such party’s Loss (whether positive or negative and without reference
to any Unpaid Amounts) for each Terminated Transaction or group of Terminated Transactions for which a Market Quotation cannot be determined or would not (in the reasonable belief of the party making the determination) produce a commercially
reasonable result. 
 “Specified Entity” has the meanings specified in the Schedule. 
  

					
		  	16	  	ISDA® 1992

 “Specified Indebtedness” means, subject to the Schedule, any obligation (whether
present or future, contingent or otherwise, as principal or surety or otherwise) in respect of borrowed money. 
 “Specified
Transaction” means, subject to the Schedule, (a) any transaction (including an agreement with respect thereto) now existing or hereafter entered into between one party to this Agreement (or any Credit Support Provider of such party
or any applicable Specified Entity of such party) and the other party to this Agreement (or any Credit Support Provider of such other party or any applicable Specified Entity of such other party) which is a rate swap transaction, basis swap, forward
rate transaction, commodity swap, commodity option, equity or equity index swap, equity or equity index option, bond option, interest rate option, foreign exchange transaction, cap transaction, floor transaction, collar transaction, currency swap
transaction, cross-currency rate swap transaction, currency option or any other similar transaction (including any option with respect to any of these transactions), (b) any combination of these transactions and (c) any other transaction
identified as a Specified Transaction in this Agreement or the relevant confirmation. 
 “Stamp Tax” means any stamp,
registration, documentation or similar tax. 
 “Tax” means any present or future tax, levy, impost, duty, charge,
assessment or fee of any nature (including interest, penalties and additions thereto) that is imposed by any government or other taxing authority in respect of any payment under this Agreement other than a stamp, registration, documentation or
similar tax. 
 “Tax Event” has the meaning specified in Section 5(b). 
 “Tax Event Upon Merger” has the meaning specified in Section 5(b). 
 “Terminated Transactions” means with respect to any Early Termination Date (a) if resulting from a Termination Event, all
Affected Transactions and (b) if resulting from an Event of Default, all Transactions (in either case) in effect immediately before the effectiveness of the notice designating that Early Termination Date (or, if “Automatic Early
Termination” applies, immediately before that Early Termination Date). 
 “Termination Currency” has the meaning
specified in the Schedule. 
 “Termination Currency Equivalent” means, in respect of any amount denominated in the
Termination Currency, such Termination Currency amount and, in respect of any amount denominated in a currency other than the Termination Currency (the “Other Currency”), the amount in the Termination Currency determined by the party
making the relevant determination as being required to purchase such amount of such Other Currency as at the relevant Early Termination Date, or, if the relevant Market Quotation or Loss (as the case may be), is determined as of a later date, that
later date, with the Termination Currency at the rate equal to the spot exchange rate of the foreign exchange agent (selected as provided below) for the purchase of such Other Currency with the Termination Currency at or about 11:00 a.m. (in the
city in which such foreign exchange agent is located) on such date as would be customary for the determination of such a rate for the purchase of such Other Currency for value on the relevant Early Termination Date or that later date. The foreign
exchange agent will, if only one party is obliged to make a determination under Section 6(e), be selected in good faith by that party and otherwise will be agreed by the parties. 
 “Termination Event” means an Illegality, a Tax Event or a Tax Event Upon Merger or, if specified to be applicable, a Credit Event
Upon Merger or an Additional Termination Event. 
 “Termination Rate” means a rate per annum equal to the arithmetic
mean of the cost (without proof or evidence of any actual cost) to each party (as certified by such party) if it were to fund or of funding such amounts. 
 “Unpaid Amounts” owing to any party means, with respect to an Early Termination Date, the aggregate of (a) in respect of all Terminated Transactions, the amounts that became payable (or that
would have become payable but for Section 2(a)(iii)) to such party under Section 2(a)(i) on or prior to such Early Termination Date and which remain unpaid as at such Early Termination Date and (b) in respect of each Terminated
Transaction, for each obligation under Section 2(a)(i) which was (or would have been but for Section 2(a)(iii)) required to be settled by delivery to such party on or prior to such Early Termination Date and which has not been so settled
as at such Early Termination Date, an amount equal to the fair market 

  

					
		  	17	  	ISDA® 1992

 
value of that which was (or would have been) required to be delivered as of the originally scheduled date for delivery, in each case together with (to the
extent permitted under applicable law) interest, in the currency of such amounts, from (and including) the date such amounts or obligations were or would have been required to have been paid or performed to (but excluding) such Early Termination
Date, at the Applicable Rate. Such amounts of interest will be calculated on the basis of daily compounding and the actual number of days elapsed. The fair market value of any obligation referred to in clause (b) above shall be reasonably
determined by the party obliged to make the determination under Section 6(e) or, if each party is so obliged, it shall be the average of the Termination Currency Equivalents of the fair market values reasonably determined by both parties.

 IN WITNESS WHEREOF the parties have executed this document on the respective dates specified below with effect from the date specified on
the first page of this document. 
  

									
	Credit Suisse First Boston International	 		 	Cheniere LNG Holdings, LLC
	 (Name of Party)
	 		 	 (Name of Party)

					
	 By:
	 	 /s/ Carole Villoresi
	 		 	 By:
	 	 /s/ Graham McArthur

		 	 Name: Carole Villoresi
	 		 		 	 Name: Graham McArthur

		 	 Title: Authorized Signatory
	 		 		 	 Title: Treasurer

		 	 Date:
	 		 		 	 Date: 12/23/05

					
	 By:
	 	 /s/ Barry Dixon
	 		 		 	
		 	 Name: Barry Dixon
	 		 		 	
		 	 Title: Authorized Signatory
	 		 		 	
		 	 Date:
	 		 		 	

  

					
		  	18	  	ISDA® 1992

 Execution Copy 
 Schedule 
 to the 
 Master Agreement 
 dated as of December 23, 2005 
 between 
  

					
	Credit Suisse First Boston International	 	and	    	Cheniere LNG Holdings, LLC
	an unlimited company incorporated	 		    	a limited liability company incorporated
	under the laws of England and Wales	 		    	under the laws of Delaware
	 (“Party A”)
	 		    	 (“Party B”)

		 		    	

 Part 1 
 Termination Provisions 
 In this Agreement: 
  

	(a)	Specified Entity. “Specified Entity” means, in relation to Party A, for the purpose of: 

  

			
	Section 5(a)(v):	  	Affiliates
	Section 5(a)(vi):	  	Not Applicable
	Section 5(a)(vii):	  	Not Applicable
	Section 5(b)(iv):	  	Not Applicable

 in relation to Party B, for the purpose of: 
  

			
	Section 5(a)(v):	  	Any Subsidiary as defined below
	Section 5(a)(vi):	  	Not Applicable
	Section 5(a)(vii):	  	Not Applicable
	Section 5(b)(iv):	  	Not Applicable

 “Subsidiary” shall mean the term “Subsidiary” as defined in the Credit Agreement described in
Part 4 (f) below. 
 (b) Specified Transaction. Specified Transaction will have the meaning specified in Section 14. 
 (c) Cross Default. The “Cross Default” provision (Section 5(a)(vi)) will apply to Party A and Party B. For Party A the Threshold Amount is $10,000,000

 In the case of Party B the only agreement or instrument that shall apply for purposes of either sub paragraph (1) or (2) of
Section 5(a)(vi) is a default by Party B under the Credit Agreement, described in Part 4 (f). For purposes of this provision, Cross Default will apply as the result of (i) any payment default under the Credit Agreement without regard to
any Threshold Amount; or (ii) the occurrence of another Event of Default under the Credit Agreement that results in the outstanding Debt thereunder being declared due and payable. 
  

 1 

 (d) Credit Event Upon Merger. The “Credit Event Upon Merger” provision (Section 5(b)(iv)) will apply to
Party A and Party B. 
 (e) Automatic Early Termination. The “Automatic Early Termination” provision of Section 6(a) will apply to
Party A and Party B. 
 (f) Payments on Early Termination. For the purpose of Section 6(e), the Second Method and Loss will apply. 
 (g) Termination Currency. “Termination Currency” means United States Dollars. 
 (h) Additional Termination Event. The following Additional Termination Event will apply: 
 the
Additional Termination Event as set forth in Part 5(k) of the Schedule to this Agreement; for the purpose of the foregoing, Party B shall be deemed to be the Affected Party and all Transactions shall be Affected Transactions. 
  

 2 

 Part 2 
 Tax Representations 
 (a) Payer Tax Representations. For the purpose of Section 3(e), Party A and Party B
each makes the following representation: 
 It is not required by any applicable law, as modified by the practice of any relevant governmental
revenue authority, of any Relevant Jurisdiction to make any deduction or withholding for or on account of any Tax from any payment (other than interest under Section 2(e), 6(d)(ii) or 6(e)) to be made by it to the other party under this
Agreement. In making this representation, it may rely on: 
  

	 	(i)	the accuracy of any representation made by the other party pursuant to Section 3(f); 

  

	 	(ii)	the satisfaction of the agreement of the other party contained in Section 4(a)(i) or 4(a)(iii) and the accuracy and effectiveness of any document provided by the other party
pursuant to Section 4(a)(i) or 4(a)(iii); and 

  

	 	(iii)	the satisfaction of the agreement of the other party contained in Section 4(d); 

 provided that it shall not be a breach of this representation where reliance is placed on clause (ii), and the other party does not deliver a form or document under Section 4(a)(iii) by reason of material
prejudice to its legal or commercial position. 
 (b) Payee Tax Representations. For the purpose of Section 3(f), 
  

	 	(i)	Party A makes the following Payee Tax Representations: 

  

	 	(1)	Party A is entering into each Transaction in the ordinary course of its trade as, and is, a recognized UK bank as defined in Section 840A of the UK Income and Corporation Taxes
Act of 1988; 

  

	 	(2)	Party A has been approved as a Withholding Foreign Partnership by the U.S. Internal Revenue Service; 

  

	 	(3)	Party A’s Withholding Foreign Partnership Employer Identification Number is 98-0330001; and 

  

	 	(4)	Party A is a partnership that agrees to comply with any withholding obligation under Section 1446 of the U.S. Internal Revenue Code. 

  

	 	(ii)	Party B makes no Payee Tax Representations. 

  

 3 

 Part 3 
 Agreement to Deliver Documents 
 Each party agrees to deliver the following documents as applicable: 
 (a) For the purpose of Section 4(a)(i), tax forms, documents or certificates to be delivered are: 
 Party A agrees to complete, accurately and in a manner reasonably satisfactory to Party B, to execute and to deliver to Party B a valid United States Internal Revenue Service Form W-8IMY, or any successor form, and
any required attachments thereto upon execution of this Agreement 
 (b) For the purpose of Section 4(a)(ii), other documents to be delivered are:

  

							
	 Party required to
deliver document
	  	 Form/Document/
Certificate
	  	 Date by Which
to be delivered
	  	 Covered by
Section 3 (d)
Representation

	Party A and	  	Evidence reasonably	  	Upon execution this	  	Yes
	Party B	  	satisfactory to the other	  	Agreement and, if	  	
		  	party as to the names,	  	requested, upon	  	
		  	true signatures and	  	execution of any	  	
		  	authority of the officers	  	Confirmation	  	
		  	or officials signing this	  		  	
		  	Agreement or any	  		  	
		  	Confirmation on its	  		  	
		  	behalf	  		  	
				
	Party A and	  	A copy of the annual	  	Upon request, or as soon	  	Yes
	Party B	  	audited or	  	as available	  	
		  	certified financial	  		  	
		  	statements for the most	  		  	
		  	recently ended financial	  		  	
		  	Year which in the case of Party A will be included in its annual report.	  		  	
				
	Party B	  	Certified resolutions	  	Upon Execution of the	  	Yes
		  	evidencing necessary	  	Agreement	  	
		  	corporate authority and	  		  	
		  	approvals with respect to	  		  	
		  	the execution, delivery	  		  	
		  	and performance by	  		  	
		  	Party B of this	  		  	
		  	Agreement and any	  		  	
		  	Confirmation delivered	  		  	
		  	thereunder on behalf of	  		  	
		  	Party B	  		  	

  

 4 

 Part 4 
 Miscellaneous 
  

													
	(a)	 	Addresses for Notices. For the purpose of Section 12(a):
			
	(i)	 	(1)	 	Address for notices or communications to Party A (other than by facsimile):
		 		 	Address:	 	One Cabot Square	  	Attention:	  	(1)	 	Head of Credit Risk Management;
		 		 		 	London E14 4QJ	  		  	(2)	 	Global Head of OTC Operations -
		 		 		 	England	  		  		 	Operations Department;
		 		 		 		  		  	(3)	 	General Counsel Europe -
		 		 		 		  		  		 	Legal and Compliance Department
				
		 		 	Swift:	 	Credit Suisse First Boston International CSFP GB2L
			
		 		 	(For all purposes.)
			
		 	(2)	 	For the purpose of facsimile notices or communications under this Agreement (other than a notice or communication under Section 5 or 6):
				
		 		 	Facsimile No.:	 	44 020 7888 2686
		 		 	Attention:	 	General Counsel Europe - Legal and Compliance Department
			
		 		 	Telephone number for oral confirmation of receipt of facsimile in legible form: 44 020 7888 2028
		 		 	Designated responsible employee for the purposes of Section 12(a)(iii): Senior Legal Secretary
			
		 		 	With a copy to:
			
		 		 	Facsimile No. 44 020 7888 3715
		 		 	Head of Credit Risk Management
			
		 		 	With a copy to:
			
		 		 	Facsimile No. 44 020 7888 9503
		 		 	Global Head of OTC Operations - Operations Department

  

									
	 (ii)
	 	Address for notices or communications to Party B:
					
		 	Address:	  	Cheniere LNG Holdings LLC	  	Attention:	  	Graham A. McArthur
		 		  	2215-B Renaissance Drive, Suite 5	  		  	Treasurer
		 		  	Las Vegas, NV 89119	  		  	
					
		 	Telephone No.:	  	713- 659-1361	  	Facsimile No.:	  	 713-659-5459

 (For all purposes.) 
 (b) Process Agent. For the purpose of Section 13(c): 
 Party A appoints as its Process Agent Credit Suisse First
Boston LLC, One Madison Avenue, New York, NY 10010 (Attention: General Counsel, Legal and Compliance Department) 
 Party B
appoints as its Process Agent: [Not Applicable] 
  

 5 

 (c) Offices. The provisions of Section 10(a) will apply to this Agreement. 
 (d) Multibranch Party. For the purpose of Section 10(c): 
 Party A is not a Multibranch Party. 
 Party B is not a Multibranch Party. 
 (e) Calculation Agent. The Calculation Agent is Party A unless otherwise agreed in a Confirmation in relation to the relevant Transaction. 
 (f) Credit Support Documents. Details of any Credit Support Document: For Party B, (i) the Credit Agreement dated as of August 31, 2005 among Cheniere
LNG Holdings, LLC, as the Borrower, the various financial institutions and other persons from time to time parties thereto, and Credit Suisse, Cayman Island Branch, as the Collateral Agent and Administrative Agent (the “Credit Agreement”),
(ii) (2) the Pledge Agreement (as defined in the Credit Agreement) and (3) the Security Agreement (as defined in the Credit Agreement) (collectively, the documents set forth are referred to herein as the “Security
Documents”) 
 (g) Credit Support Provider. 
 Credit Support Provider means in relation to Party A: Not applicable 
 Credit
Support Provider means in relation to Party B the Pledgor under the Pledge Agreement defined in Part4(f). 
 (h) Governing Law. This Agreement will be
governed by and construed in accordance with the laws of the State of New York. Section 13(b) is hereby amended by: (i) deleting in the second line of subparagraph (i) thereof the word, “non-”; (ii) adding in the third
line before the comma, “and each party irrevocably agrees to designate any Proceedings brought in the courts of the State of New York as ‘commercial’ on the Request for Judicial Intervention seeking assignment to the Commercial
Division of the Supreme Court”; and (iii) inserting “in order to enforce any judgment obtained in any Proceedings referred to in the preceding sentence” immediately after the word, “jurisdiction” the first time it
appears in the second sentence and deleting the remainder. 
 (i) Netting of Payments. Section 2(c)(ii) of this Agreement will apply to any
Transactions from the date of this Agreement. Nevertheless, to reduce settlement risk and operational costs, the parties agree that they will endeavour to net across as many Transactions as practicable wherever the parties can administratively do
so. 
 (j) Affiliate. Affiliate will have the meaning specified in Section 14. 
  

 6 

 Part 5 
 Other Provisions 
 (a) Scope of Agreement. Any Specified Transaction (whether now existing or hereafter
entered into) between the parties, the confirmation of which fails by its terms expressly to exclude application of this Agreement, shall be governed by and be subject to this Agreement. Any such confirmation shall be a “Confirmation”, and
any such Specified Transaction shall be a “Transaction”, for all purposes of this Agreement. 
 (b) Definitions. Unless otherwise
specified in a Confirmation, each Transaction between the parties shall be subject to the 2000 ISDA Definitions as published by the International Swaps and Derivatives Association, Inc. (the “2000 Definitions”), and will be governed in all
relevant respects by the provisions of the 2000 Definitions, without regard to any amendments thereto subsequent to the date hereof. The provisions set forth in the 2000 Definitions are incorporated by reference in and shall be deemed a part of this
Agreement except that references in the 2000 Definitions to a “Swap Transaction” shall be deemed references to a “Transaction” for purposes of this Agreement. 
 (c) Confirmations. Each Confirmation shall be substantially in the form of one of the Exhibits to the 2000 Definitions or in any other form that is published by the International Swaps and Derivatives
Association, Inc. or in such other form as the parties may agree. 
 (d) Relationship Between Parties. The parties agree to amend
Section 3 of this Agreement by the addition of the following provision at the end thereof and marked as subsection (g). 
  

	 	“(g)	Relationship Between Parties. Each party will be deemed to represent to the other party on the date on which it enters into a Transaction that (absent a written agreement
between the parties that expressly imposes affirmative obligations to the contrary for that Transaction): 

 “(i)
Non-Reliance. It is acting for its own account, and it has made its own independent decisions to enter into that Transaction and as to whether that Transaction is appropriate or proper for it based upon its own judgment and upon advice from
such advisers as it has deemed necessary. It is not relying on any communication (written or oral) of the other party as investment advice or as a recommendation to enter into that Transaction; it being understood that information and explanations
related to the terms and conditions of a Transaction shall not be considered investment advice or a recommendation to enter into that Transaction. No communication (written or oral) received from the other party shall be deemed to be an assurance or
guarantee as to the expected results of that Transaction. 
 “(ii) Assessment and Understanding. It is capable of
assessing the merits of and understanding (on its own behalf or through independent professional advice), and understands and accepts, the terms, conditions and risks of that Transaction. It is also capable of assuming, and assumes, the risks of
that Transaction. 
 “(iii) Status of Parties. The other party is not acting as a fiduciary for or an adviser to it in respect of
that Transaction. 
 “(iv) No Agency. It is entering into this Agreement, including each Transaction, as principal and not as
agent of any person or entity.” 
 (e) Change of Account. Section 2(b) of this Agreement is hereby amended by the addition of the following
after the word “delivery” in the first line thereof: 
 “to another account in the same legal and tax jurisdiction as the
original account” 
 (f) Escrow Payments. If (whether by reason of the time difference between the cities in which payments are to be made or
otherwise) it is not possible for simultaneous payments to be made on any date on which both parties are required to make payments hereunder, either party may at its option and in its sole discretion notify the other party that payments on that date
are to be made in escrow. In this case deposit of the payment due earlier on that date shall be made by 2:00 p.m. (local time at the place for the earlier payment) on that date with an escrow agent 

  

 7 

 
selected by the notifying party, accompanied by irrevocable payment instructions (i) to release the deposited payment to the intended recipient upon
receipt by the escrow agent of the required deposit of the corresponding payment from the other party on the same date accompanied by irrevocable payment instructions to the same effect or (ii) if the required deposit of the corresponding
payment is not made on that same date, to return the payment deposited to the party that paid it into escrow. The party that elects to have payments made in escrow shall pay all costs of the escrow arrangements. 
 (g) Set-off. Without affecting the provisions of this Agreement requiring the calculation of certain net payment amounts, all payments under this Agreement will
be made without set-off or counterclaim; provided, however, that upon the designation of any Early Termination Date, in addition to and not in limitation of any other right or remedy (including any right to set-off, counterclaim, or otherwise
withhold payment) under applicable law: 
 the Non-defaulting Party or the party that is not the Affected Party (in either case,
“X”) may, without prior notice to any person, set off any sum or obligation (whether or not arising under this Agreement, whether matured or unmatured and irrespective of the currency, place of payment or booking office of the sum or
obligation) owed by the Defaulting Party or Affected Party (in either case, “Y”) to X or to any Affiliate of X, against any sum or obligation (whether or not arising under this Agreement or any other agreement, whether matured or unmatured
and irrespective of the currency, place of payment or booking office of the sum or obligation) owed by X or any Affiliate of X to Y, and, for this purpose, may convert one currency into another. If any sum or obligation is unascertained, X may in
good faith estimate that sum or obligation and set off in respect of that estimate, subject to X or Y, as the case may be, accounting to the other party when such sum or obligation is ascertained. 
 Nothing in this Agreement shall be effective or deemed to create any charge under English law. 
 (h) Recording of Conversation. Each party to this Agreement acknowledges and agrees to the tape recording of conversations between the parties to this Agreement
whether by one or other or both of the parties and each party hereby consents to such recordings being used as evidence in Proceedings. 
 (i) Commodity
Exchange Act. Each party represents to the other party on and as of the date hereof and on each date on which a Transaction is entered into among them that: 
  

	 	(i)	such party is an “eligible contract participant” as defined in the U.S. Commodity Exchange Act, as amended (the “CEA”); 

  

	 	(ii)	neither this Agreement nor any Transaction has been executed or traded on a “trading facility” as such term is defined in the CEA; and 

  

	 	(iii)	such party is entering into each Transaction in connection with its business or a line of business and the terms of this Agreement and each Transaction have been individually
tailored and negotiated. 

 (j) Waiver of Right to Trial by Jury. Each party waives, to the fullest extent permitted by applicable law,
any right it may have to a trial by jury in respect of any suit, action or proceeding relating to this Agreement or any Credit Support Document. Each party (i) certifies that no representative, agent or attorney of the other party or any Credit
Support Provider has represented, expressly or otherwise, that such other party would not, in the event of such a suit action or proceeding, seek to enforce the foregoing waiver and (ii) acknowledges that it and the other party have been
induced to enter into this Agreement and provide for any Credit Support Document, as applicable by, among other things, the mutual waivers and certifications in this Section. 
 (k) Additional Representations and Obligations of Party B. Party B represents and warrants to Party A and further covenants that its payment obligations hereunder (or with respect to any Transaction) are or
shall be secured pari passu in all respects and at all times with all of Party B’s senior secured obligations. It shall constitute an Additional Termination Event (with Party B as the sole Affected Party) if at any time the
“Collateral” (as defined in the Credit Agreement ) fails to secure Party B’s obligations to Party A hereunder (or under any and all particular Transactions to which Party B is a party) to the same extent as such Collateral secures
Party B’s Obligations under the Loan Documents (as such capitalized terms are defined in the Credit Agreement) and the payment obligations 

  

 8 

 
hereunder (or under any and all particular Transactions to which Party B is a party) fail to rank at least pari passu in all respects and at all times
with all of Party B’s other Obligations under the Credit Agreement. 
 IN WITNESS WHEREOF, the parties hereto have executed this
document as of the date specified on the first page hereof. 
  

									
	Credit Suisse First Boston International	 		 	Cheniere LNG Holdings, LLC
					
	 By:
	 	 /s/ Carole Villoresi
	 		 	 By:
	 	 /s/ Graham McArthur

	 Name:
	 	 Carole Villoresi
	 		 	 Name:
	 	 Graham McArthur

	 Title:
	 	 Authorized Signatory
	 		 	 Title:
	 	 Treasurer

	 Date:
	 		 		 	 Date:
	 	 December 23, 2005

					
	 By:
	 	 /s/ Barry Dixon
	 		 		 	
	 Name:
	 	 Barry Dixon
	 		 		 	
	 Title:
	 	 Authorized Signatory
	 		 		 	
	 Date:
	 		 		 		 	

  

 9Agreement for Engineering, Procurement and Construction Services

 Exhibit 10.53 
 EXECUTION COPY 
 AGREEMENT 
 For 
 ENGINEERING, PROCUREMENT, AND 
 CONSTRUCTION SERVICES 
 for

 42 - INCH SABINE PASS PIPELINE PROJECT 
 between 
 CHENIERE SABINE PASS PIPELINE COMPANY 
 and 
 WILLBROS ENGINEERS, INC.

 AGREEMENT 
 THIS AGREEMENT for Engineering, Procurement and Construction Services (the “Agreement”) is made and entered into effective as of this 1st day of February 2006 (“Effective Date”) by and
between Cheniere Sabine Pass Pipeline Company, a company organized under the laws of the State of Delaware (“Cheniere”), and Willbros Engineers, Inc., a company incorporated under the laws of the State of Delaware (“Willbros”).
Cheniere and Willbros are hereinafter sometimes referred to individually as a “Party” or collectively as the “Parties.” 
 WHEREAS, Cheniere desires to design, build, own and operate the 16.0-mile, 42-inch pipeline and related facilities to be constructed from the Cheniere liquefied natural gas terminal to a pipeline interconnect at Johnson’s Bayou,
all located entirely in Cameron Parish, Louisiana (as more fully described herein, the “Project”); and 
 WHEREAS, Willbros,
itself or through its Subcontractors or Vendors desires to provide engineering, procurement and construction services related to the Project; 
 NOW, THEREFORE, in consideration of the mutual covenants herein and for other good and valuable consideration, the receipt and sufficiency of which are acknowledged, Cheniere and Willbros hereby agree as follows: 
 1. SCOPE OF WORK 
  

	1.1	In close cooperation and coordination with Cheniere and subject to Paragraph 1.3 below, Willbros agrees to perform the Work, including all Project management, engineering,
procurement, construction and construction management for the Project, and provide all equipment, materials, supplies, labor workmanship, apparatus, machinery, tools, structures, inspection, manufacture, fabrication, installation, design, delivery,
transportation, storage and any incidental work reasonably inferable as required and necessary to complete the Project in accordance with Applicable Law, Applicable Codes and Standards and all other provisions of this Agreement. Without limiting the
generality of the foregoing, the Work is described in more particular detail in the Scope of Work set forth in Schedule “B”. 

  

	1.2	The Scope of Work is based upon and shall comply with the preliminary engineering developed by Cheniere’s other consultants and contractors and the FERC Certificate.

  

	1.3	Willbros shall not be responsible for and the Work excludes the Cheniere Provided Items identified in Paragraph 5.3 which are to be provided by Cheniere. 

2. PROJECT SCHEDULE 
 The
Work shall be performed in accordance with the dates set forth in the Project Schedule attached as Schedule “F”. 
  

 1 

 3. COMPENSATION 
 Willbros will submit invoices, and Cheniere shall pay Willbros the amounts due in accordance with Paragraph 5.4 of Schedule “A”. The sum
of the Cost of the Work, the Willbros Management Fee and the Contingency Costs is guaranteed by Willbros not to exceed Sixty-Seven Million Six Hundred Seventy Thousand Two Hundred Dollars ($67,670,200), subject to additions and deductions by Change
Order as provided herein (the “Guaranteed Maximum Price”), excluding Louisiana sales and use taxes applicable to permanent materials and equipment to be incorporated into the Project, which shall be reimbursed by Cheniere in accordance
with Paragraph 5.4.2 of Schedule “A”. Costs which would cause the Guaranteed Maximum Price to be exceeded shall be paid by Willbros without reimbursement by Cheniere. 
 4. GENERAL 
  

	4.1	The Agreement consists of this signed document (the “Signature Document”) and the following attached Schedules, which by this reference are incorporated herein and made a
part hereof: 

  

					
	 Schedule “A”  -    Terms and Conditions

	 Attachment I
	 	-	  	Willbros Parent Guarantee
	 Attachment II
	 	-	  	Payment Bond, Performance Bond and Riders
	 Attachment III
	 	-	  	Mechanical Completion Certificate
	 Attachment IV
	 	-	  	Project Completion Certificate
	 Attachment V
	 	-	  	Start-up Certificate
	 Attachment VI
	 	-	  	Change Order Form
	 Attachment VII
	 	-	  	Approved Subcontractors and Vendors List
	 Attachment VIII
	 	-	  	Organizational Chart
	 Attachment IX
	 	-	  	Cheniere’s Health, Safety and Environmental Policies
	 Attachment X
	 	-	  	Lien and Claim Waivers
	 Schedule “B”  -    Scope of Work for the Project

	 Attachment I
	 	-	  	Work Site
	 Schedule “C”  -    Intentionally Omitted

	
	 Schedule “D”  -    Applicable Codes and Standards, Drawings and
Specifications

	 Attachment I
	 	-	  	Drawings
	 Attachment II
	 	-	  	Specifications
	
	 Schedule “E”  -    Intentionally Omitted

	 Schedule “F”  -    Project Schedule

  

	4.2	A reference in the Agreement to any of the Schedules shall, in addition, be considered a reference to any Attachments to said Schedules, and to all documents referred to in said
Schedules or Attachments. 

  

	4.3	 Any notice, demand, offer or other written instrument required or permitted to be given pursuant to this Agreement shall be in writing and signed by the Party
giving such notice 

  

 2 

	 	 
and shall be sufficient when delivered in person or sent by e-mail, by facsimile, or by certified or registered mail, to the other Party at the appropriate
address as follows: 

  

			
	 If delivered to Cheniere:
	  	 If delivered to Willbros:

	Richard E. Keyser	  	Willbros Engineers, Inc.
	Cheniere Sabine Pass Pipeline	  	2087 East 71st Street
	717 Texas Avenue, Suite 3100	  	P.O. Box 701650
	Houston, Texas 77002	  	Tulsa, Oklahoma 74170
	Telephone: (832) 204-2284	  	Telephone: (918) 481-4163
	Fax: (713) 659-5459	  	Fax: (918) 493-3430
	Attention: Mr. Richard E. Keyser	  	Attention: Mr. Curtis E. Simkin
	E Mail: rkeyser@cheniere.com	  	E Mail: curt.simkin@willbros.com
		
	 Copy to:
	  	 Copy to:

	Allan Bartz	  	Willbros Engineers, Inc
	Cheniere Sabine Pass Pipeline	  	2087 East 71st Street
	717 Texas Avenue, Suite 3100	  	P.O. Box 701650
	Houston, Texas 77002	  	Tulsa, Oklahoma 74170
	Telephone: (713) 659-1361	  	Telephone: (918) 499-3706
	Fax: (713) 659-5459	  	Fax: (918) 499-3702
	Attention: Mr. Allan Bartz	  	Attention: Mr. Mike Reifel
	E Mail: abartz@cheniere.com	  	E Mail: mike.reifel@willbros.com

 Willbros or Cheniere may notify the other at any time of a change in, or addition to, the addresses
and/or persons to which communications should be sent. Notices, demands, offers or other written instruments shall be deemed to have been duly given on the date actually received by its intended recipient. 
 IN WITNESS WHEREOF, Cheniere and Willbros have executed duplicate originals of the Agreement, effective and binding as of the Effective Date. 
  

									
	 Witness
	 		 	 Cheniere Sabine Pass Pipeline Company

				
	 /s/ Richard Keyser
	 		 	 By:
	 	 /s/ Robert Keith Teague

		 		 		 	 Title:  President

		 		 		 	 Date:  February 21, 2006

			
	 Witness
	 		 	 Willbros Engineers, Inc.

				
	 /s/ Kevin R. Fox
	 		 	 By:
	 	 /s/ Curtis E. Simpkin

		 		 		 	 Title:  President

		 		 		 	 Date:  February 1, 2006

  

 3 

 SCHEDULE “A” 
 TERMS AND CONDITIONS 
 TABLE OF CONTENTS 
  

			
	 1. DEFINITIONS
	  	A-2
	 2. WILLBROS’ OBLIGATIONS
	  	A-9
	 3. WILLBROS PERSONNEL AND EQUIPMENT
	  	A-12
	 4. WORK SITE RESPONSIBILITIES
	  	A-14
	 5. CHENIERE’S OBLIGATIONS
	  	A-15
	 6. WORK PLAN AND REPORTS
	  	A-20
	 7. INSPECTION AND TESTING
	  	A-22
	 8. COMPLETION AND START-UP
	  	A-23
	 9. CHANGES
	  	A-25
	 10. INDEMNITY, LIENS AND PATENTS
	  	A-26
	 11. INSURANCE
	  	A-30
	 12. WARRANTY
	  	A-34
	 13. TITLE TO THE WORK AND TO WORK PRODUCT, CONFIDENTIAL INFORMATION
	  	A-37
	 14. DISPUTE RESOLUTION
	  	A-40
	 15. SUSPENSION OF WORK
	  	A-42
	 16. TERMINATION AT CHENIERE’S CONVENIENCE
	  	A-43
	 17. TERMINATION BY CHENIERE FOR CAUSE
	  	A-44
	 18. TERMINATION BY WILLBROS
	  	A-45
	 19. WILLBROS’ OBLIGATIONS UPON SUSPENSION OR TERMINATION
	  	A-45
	 20. FORCE MAJEURE AND CHENIERE-CAUSED DELAY
	  	A-46
	 21. LIQUIDATED DAMAGES
	  	A-48
	 22. PUBLICITY RELEASES
	  	A-49
	 23. GOVERNING LAW
	  	A-49
	 24. GENERAL PROVISIONS
	  	A-49

  

					
	 ATTACHMENT I
	  	–	  	 WILLBROS PARENT GUARANTEE

	 ATTACHMENT II
	  	–	  	 PAYMENT BOND, PERFORMANCE BOND AND RIDERS

	 ATTACHMENT III
	  	–	  	 MECHANICAL COMPLETION CERTIFICATE

	 ATTACHMENT IV
	  	–	  	 PROJECT COMPLETION CERTIFICATE

	 ATTACHMENT V
	  	–	  	 START-UP CERTIFICATE

	 ATTACHMENT VI
	  	–	  	 CHANGE ORDER FORM

	 ATTACHMENT VII
	  	–	  	 APPROVED SUBCONTRACTORS AND VENDORS LIST

	 ATTACHMENT VIII
	  	–	  	 ORGANIZATIONAL CHART

	 ATTACHMENT IX
	  	–	  	 CHENIERE’S HEALTH, SAFETY AND ENVIRONMENTAL POLICIES

	 ATTACHMENT X
	  	–	  	 LIEN AND CLAIM WAIVERS

  

 A-1 

 SCHEDULE “A” 
 TERMS AND CONDITIONS 
 1. DEFINITIONS 
 The following terms shall have the meanings indicated for all purposes of the Agreement and the use of the singular includes the plural, and vice versa: 
  

	1.1	“AAA” has the meaning set forth in Paragraph 14.3. 

  

	1.2	“AAA Rules” has the meaning set forth in Paragraph 14.3. 

  

	1.3	“Actual Contract Amount” has the meaning set forth in Attachment I of the Letter Agreement. 

  

	1.4	“Agreement” has the meaning set forth in, and incorporates by reference the documents as stated in, Paragraph 4.1 of the Signature Document. 

  

	1.5	“Amendment” means any written modification of the Agreement, signed by both Cheniere and Willbros, other than Change Orders. 

  

	1.6	“Applicable Codes and Standards” means any and all codes, standards or requirements set forth herein (including Schedule “D”) or in any Applicable Law,
which codes, standards and requirements shall govern Willbros’ performance of the Work, as provided herein. In the event of an inconsistency or conflict between any of the Applicable Codes and Standards, the highest performance standard as
contemplated therein shall govern Willbros’ performance. 

  

	1.7	“Applicable Law” means all laws, statutes, ordinances, certifications, orders, decrees, injunctions, permits, agreements, rules and regulations, including any conditions
thereto, of any Governing Authority having jurisdiction over all or any portion of the Work Site or the Project or performance of all or any portion of the Work, or other legislative or administrative action of a Governing Authority, or a final
decree, judgment or order of a court which relates to the performance of Work hereunder or the interpretation or application of this Agreement, including (a) any and all permits, authorizations, certifications, or other approvals or orders,
(b) any Applicable Codes and Standards set forth in Applicable Law and (c) any Applicable Law related to (i) conservation, regulation, improvement, protection, pollution, contamination or remediation of the environment or
(ii) Hazardous Substances or any handling, treatment, storage, release, use and disposal or other disposition of Hazardous Substances, including the Comprehensive Environmental Response, Compensation and Liability Act (“CERCLA”).

  

	1.8	“Books and Records” has the meaning set forth in Paragraph 2.9. 

  

 A-2 

	1.9	“Catastrophic Storms” means storms which are listed by the National Oceanic and Atmospheric Administration as Billion Dollar U.S. Weather Disasters.

  

	1.10	“Change” means an addition, deletion, suspension of, revision or any other modification or Amendment to the Work. Adjustment to the Guaranteed Maximum Price, the
Preparation and Material Receipt Commencement Date, the Construction Commencement Date or the Scheduled Mechanical Completion Date shall in every instance constitute a Change. 

  

	1.11	“Change Order” means a document, in the form attached hereto as Attachment VI and signed by Cheniere and Willbros, issued on or after the Effective Date,
authorizing a Change to the Work, the Guaranteed Maximum Price, the Preparation and Material Receipt Commencement Date, the Scheduled Mechanical Completion Date, the Construction Commencement Date or any other material requirement under this
Agreement. 

  

	1.12	“Cheniere” has the meaning set forth in the introductory paragraph of the Signature Document. 

  

	1.13	“Cheniere’s Authorized Representative” means Richard E. Keyser, the person hereby authorized by Cheniere to act on its behalf on all matters pertaining to the
Agreement, and whose actions shall be binding upon Cheniere. 

  

	1.14	“Cheniere’s Confidential Information” has the meaning set forth in Paragraph 13.6. 

  

	1.15	“Cheniere Group” means the owners and affiliated companies of Cheniere or its lenders, including, their respective officers, directors, employees, agents, representatives,
contractors (excluding Willbros, its affiliates, Subcontractors and Vendors) and subcontractors. 

  

	1.16	“Cheniere Provided Items” means those items to be provided by Cheniere, and those responsibilities to be performed by Cheniere, as described in Paragraph 5.3.

  

	1.17	“Claim” has the meaning set forth in Paragraph 10.1.1. 

  

	1.18	“Confidential Information” has the meaning set forth in Paragraph 13.8. 

  

	1.19	“Construction Commencement Date” means the date set forth in Paragraph 6.1.2. 

  

	1.20	“Contingency Costs” means those reasonable costs actually incurred incident to the performance of Work under this Agreement and prior to Project Completion of the Project,
which are not reimbursable as a Cost of the Work, are not attributable to Willbros’ negligence, willful misconduct or breach of this Agreement, are not recoverable from Subcontractors, Vendors or insurers, and for which records required
hereunder exist and are contemporaneously prepared and maintained (“Contingency Costs”). 

  

 A-3 

	1.21	“Contingency Pool” has the meaning set forth in Attachment I of the Letter Agreement. 

  

	1.22	“Contract Amount” has the meaning set forth in Paragraph 5.4.1. 

  

	1.23	“Corrective Work” has the meaning set forth in Paragraph 12.2.2. 

  

	1.24	“Cost of the Work” has the meaning set forth in Paragraph 5.4.1. 

  

	1.25	“Defect” or “Defective” has the meaning set forth in Paragraph 12.1. 

  

	1.26	“Defect Correction Period” has the meaning set forth in Paragraph 12.2.2. 

  

	1.27	“Disclosing Party” has the meaning set forth in Paragraph 13.8. 

  

	1.28	“Dispute” has the meaning set forth in Paragraph 14.2. 

  

	1.29	“Dispute Notice” has the meaning set forth in Paragraph 14.2. 

  

	1.30	“Drawings” means drawings developed by Willbros and approved by Cheniere for the performance of the Project in accordance with Paragraph 2.7, Paragraph 2.8 and Schedule
“B” and as listed in Schedule “D”. The Drawings shall be based on the Specifications. Should there be an inconsistency between the Specifications and the Drawings, the Specifications shall prevail.

  

	1.31	“E&O Insurance” has the meaning set forth in Paragraph 11.1.7. 

  

	1.32	“Effective Date” shall be the date given in the introductory paragraph of the Signature Document. 

  

	1.33	“Exception Items” means finishing items required to complete various portions of the Work which are incomplete, Defective or otherwise not in accordance with the
Agreement, but the completion of which shall not affect, interrupt, disrupt, or interfere with the safe and orderly operation of all or a part of the Project as more fully described in Paragraph 8. 

  

	1.34	“FERC Certificate” means that certification issued by the Federal Energy Regulatory Commission (“FERC”) (i) authorizing the construction of the Project,
including any conditions governing the conduct of the construction activities for the Project, and (ii) detailing the pipeline route and required pipe class associated with the route’s population density survey. The FERC Certificate
includes related FERC filing documents CP04-38-00, CP04-38-001, CP04-39-000 and CP04-40-000 and the approved implementation plan. 

  

	1.35	 “Force Majeure” means Catastrophic Storms or floods, lightning, tornadoes, hurricanes, named tropical storms, earthquakes and other acts of God, wars,
civil disturbances, terrorist attacks, revolts, insurrections, sabotage, commercial embargoes, epidemics, fires, 

  

 A-4 

	 	 
explosions, and actions of a Governing Authority that were not requested, promoted, or caused by the affected Party, and strikes or other similar labor
actions (except as set forth in (iii) below); provided that such act or event (a) renders impossible or impracticable the affected Party’s performance of its obligations under the Agreement, (b) is beyond the reasonable control
of the affected Party and not due to its fault or negligence and (c) could not have been prevented or avoided by the affected Party through the exercise of due diligence, including the expenditure of any reasonable sum taking into account the
Guaranteed Maximum Price. For avoidance of doubt, Force Majeure shall not include any of the following: (i) a Party’s economic hardship, (ii) changes in market conditions, (iii) strikes, or other similar labor actions to the
extent caused by the act or omission of the Party claiming Force Majeure, (iv) unavailability of Subcontractors or Vendors; (v) climatic conditions (including rain, snow, wind, temperature and other weather conditions), tides, and seasons,
regardless of the magnitude, severity, duration or frequency of such climatic conditions (except those Catastrophic Storms as set forth above), or (vi) nonperformance or delay by Willbros or its Subcontractors or Vendors, unless any of the
foregoing conditions is otherwise caused by Force Majeure. 

  

	1.36	“Guaranteed Maximum Price” shall have the meaning set forth in Paragraph 3 of the Signature Document. 

  

	1.37	“Governing Authority” means any federal, state, or local department, office, instrumentality, agency, board or commission having jurisdiction over a Party or any portion
of the Work, the Work Site or the Project. 

  

	1.38	“Hazardous Substance” means any substance that under Applicable Law is considered to be hazardous or toxic or is or may be required to be remediated, including
(a) “hazardous substances” as defined in 42 U.S.C. § 9601(14), (b) “chemicals” subject to regulation under Title III of the Superfunds Amendments and Reauthorization Act (“SARA”) of 1986, (c) natural
gas liquids, liquefied natural gas or synthetic gas, (d) any petroleum, petroleum-based products or crude oil or any fraction, or (e) any other chemical, waste, material, pollutant, contaminant or any other substance, exposure to which is
now or hereafter prohibited, limited or regulated by any Governing Authority or which may be the subject of liability for damages, costs or remediation. 

  

	1.39	“Key Personnel” or “Key Persons” has the meaning set forth in Paragraph 3.1 and includes the Willbros Personnel listed in Attachment VIII.

  

	1.40	“Letter Agreement” means that letter agreement entered into between the Parties simultaneously with this Agreement dated February 01, 2006. 

 

	1.41	“Liquidated Damages” has the meaning set forth in Paragraph 21.1. 

  

	1.42	 “Major Vendor” means any Vendor (a) who has entered a subcontract or purchase order having an aggregate value in excess of One Hundred Thousand
Dollars ($100,000), or (b)

  

 A-5 

	 	 
who has entered multiple subcontracts or purchase orders with an aggregate value in excess of One Hundred Thousand Dollars ($100,000).

  

	1.43	“Mechanical Completion” or “Mechanically Complete” means that all of the following has occurred: (a) the Work is approved by Cheniere as being ready for
pre-commissioning and/or commissioning; (b) Willbros has delivered to Cheniere a set of original test and inspection certificates, including hydrostatic test reports, materials documentation, MAOP establishment records, and internal geometry
pig results; (c) Willbros has completed all construction, procurement, fabrication, assembly, erection, installation and testing, including final pipeline hydrostatic tests for the pipeline and all appropriate appurtenances to ensure that such
systems were correctly constructed, procured, fabricated, assembled, erected, installed and tested and are capable of being operated safely and reliably within the requirements contained in this Agreement; (d) Willbros has delivered to Cheniere
a Mechanical Completion Certificate for the Project in the form of Attachment III, and Cheniere has accepted such certificate by signing such certificate; (e) Willbros has dewatered and dried the pipeline to a dewpoint of negative forty
degrees Fahrenheit (-40oF); (f) Willbros has completed all Exception Items in accordance with Paragraph 8.1; and (g) Willbros has performed all other obligations required under this Agreement for Mechanical Completion.

  

	1.44	“QA/QC Plan” has the meaning set forth in Paragraph 7.1. 

  

	1.45	“Party” or “Parties” has the meaning set forth in the introductory paragraph of the Signature Document. 

  

	1.46	“Paragraph” means a paragraph in the Schedule in which it appears, unless otherwise indicated. 

  

	1.47	“Preparation and Material Receipt Commencement Date” has the meaning set forth in Paragraph 6.1.1. 

  

	1.48	“Project” means the whole of the Work to be performed by Willbros in respect of the pipeline and in accordance with this Agreement, including the construction, testing,
and commissioning of the 16-mile, 42-inch pipeline and related facilities, including an inlet monitor regulator station, a pig launcher, a 30-inch side tap, a 42-inch side tap, two- 42-inch mainline valves, and all other appropriate valves and
appurtenances, to be constructed from the Cheniere liquefied natural gas terminal to a pipeline interconnect at Johnson’s Bayou, all located entirely in Cameron Parish, Louisiana; for purposes of clarification, the Project does not include the
NGPL Meter Station and the Cameron Meadows Meter Station being developed by Cheniere. 

  

	1.49	 “Project Completion” means the date when all Work and all other obligations under this Agreement are fully and completely performed in accordance with the
terms of this Agreement, including: (a) the successful achievement of Mechanical Completion of all systems for the Project; (b) the successful achievement of Start-up of all systems for the 

  

 A-6 

	 	 
Project; (c) delivery by Willbros of all documentation required to be delivered under this Agreement, including any Work Product, Cheniere’s
Confidential Information and other documentation; (d) delivery by Willbros to Cheniere of fully executed Final Lien and Claim Waivers in the form of Attachment X – Part 2; (e) removal from the Work Site of all of Willbros
Personnel, supplies, waste, materials, rubbish and temporary facilities and restoration of the Work Site to its natural conditions in accordance with this Agreement, Applicable Law and Applicable Codes and Standards or any other requirements of any
Governing Authority; (f) delivery by Willbros to Cheniere of a Project Completion Certificate in the form of Attachment IV, which Cheniere has accepted by signing such certificate; (g) delivery by Willbros to Cheniere of evidence
acceptable to Cheniere that all Subcontractors and Vendors have been fully and finally paid, including fully executed Final Lien and Claim Waivers from all Subcontractors and Major Vendors in the form of Attachment X – Part 4;
(h) Willbros has completed all Exception Items in accordance with Paragraph 8.3; and (i) performance of all other obligations required by this Agreement for Project Completion. 

  

	1.50	“Project Schedule” means the dates for performance of the Work set forth in Schedule “F”, including the Preparation and Material Receipt Commencement
Date, the Scheduled Mechanical Completion Date and the Construction Commencement Date. 

  

	1.51	“Receiving Party” has the meaning set forth in Paragraph 13.8. 

  

	1.52	“Schedule of Values” has the meaning set forth in Paragraph 5.4.13. 

  

	1.53	“Scheduled Mechanical Completion Date” means the date set forth in Paragraph 6.1.3. 

  

	1.54	“Shared Savings” has the meaning set forth in Attachment I of the Letter Agreement. 

  

	1.55	“Signature Document” means the cover document to which all Schedules of the Agreement are attached thereto and which contains the signature page for which the Parties have
signed in order to be bound by this Agreement. 

  

	1.56	“Specifications” means those items and requirements governing the performance and standards of the Work as set forth in this Agreement, including the FERC Certificate and
those standard engineering and construction specifications developed by Willbros in accordance with Paragraph 2 and approved by Cheniere and as set forth or incorporated by reference in Schedule “D”. 

  

	1.57	“Start-up” means that all of the following has occurred: (a) the successful achievement of Mechanical Completion of all systems for the Project; (b) Cheniere has
purged the Project with either natural gas or nitrogen with assistance and support from Willbros as requested; (c) delivery by Willbros to Cheniere of a Start-up Certificate in the form of Attachment V, which Cheniere has accepted by
signing such certificate; (d) Willbros has completed all Exception Items in accordance with Paragraph 8.2; and (e) performance of all other obligations required by this Agreement for Start-up. 

  

 A-7 

	1.58	“Subcontractor” means any person or entity (other than a Vendor), of any tier, who performs any portion of the Work or otherwise furnishes labor, materials, supplies or
equipment which are a portion of the Work or in connection with the Work and who is not a direct full-time employee of Willbros. The term “Subcontractor” may be referred to throughout the Agreement as if singular in number and means a
Subcontractor or an authorized representative of Subcontractor. 

  

	1.59	“Taxes” has the meaning set forth in Paragraph 5.4.2. 

  

	1.60	“Vendor” means any person or entity, including a Major Vendor, (other than a Subcontractor), of any tier, including materialmen and equipment suppliers or renters, who,
sells or supplies materials, supplies or equipment which are to be incorporated into the Work or used in connection with the Work and who is not a direct full-time employee of Willbros. The term “Vendor” may be referred to throughout the
Agreement as if singular in number and means a Vendor or an authorized representative of a Vendor. 

  

	1.61	“Warranty” has the meaning set forth in Paragraph 12.1. 

  

	1.62	“Willbros” has the meaning set forth in the introductory paragraph of the Signature Document. 

  

	1.63	“Willbros Authorized Representative” means Mike Reifel, the person hereby authorized by Willbros to act on its behalf on all matters pertaining to the Agreement, and whose
actions shall be binding upon Willbros. 

  

	1.64	“Willbros’ Confidential Information” has the meaning set forth in Paragraph 13.7. 

  

	1.65	“Willbros Equipment” means all machinery, apparatus, equipment, materials, tools, temporary facilities and other items previously owned by Willbros or rented for the
purposes of this Project and utilized by Willbros to perform the Work but not forming a part of the Project, including also that of its Subcontractors and Vendors at whatever tier. 

  

	1.66	“Willbros’ Intellectual Property” has the meaning set forth in Paragraph 13.4. 

  

	1.67	“Willbros Management Fee” means Willbros’ lump sum fee for overhead, profit and indirect job risk which is set forth in the Schedule of Values.

  

	1.68	“Willbros Personnel” means all labor, supervisory and other personnel utilized by Willbros to perform the Work, including also those of its Subcontractors and Vendors at
whatever tier. 

  

	1.69	“Willbros Group” means the owners and affiliated companies of Willbros Engineers, Inc., and their respective officers, directors, employees, agents, representatives,
Subcontractors, and Vendors. 

  

 A-8 

	1.70	“Willbros RPI, Inc.” means the Willbros Group affiliated construction company headquartered in Houston, Texas that may be a Subcontractor to Willbros Engineers, Inc. on
this Project. 

  

	1.71	“Work” means all the work, services, duties, responsibilities and other undertakings to be performed by Willbros, its Subcontractors or its Vendors as described in this
Agreement, including that set forth in Schedule “B” and Paragraphs 2, 3 and 4. 

  

	1.72	“Work Plan” means the plan described in Paragraph 6.2 and formulated pursuant to Schedule “B” and Schedule “F” of the Agreement.

  

	1.73	“Work Product” has the meaning set forth in Paragraph 13.3. 

  

	1.74	“Work Site” means the location on which the Project shall be located which is identified in more detail in Attachment I of Schedule “B”.

 2. WILLBROS’ OBLIGATIONS 
 Subject to Paragraph 5 and in close cooperation and coordination with Cheniere, and subject to the terms and conditions of the Agreement, Willbros shall perform the Work in accordance with good engineering and
construction practices, Applicable Law, Applicable Codes and Standards, the Specifications and all other provisions of this Agreement. Willbros accepts the relationship of trust and confidence established by this Agreement and covenants with
Cheniere to exercise its skill and judgment in furthering the interests of Cheniere. Without limiting the generality of the foregoing or the requirements of any other provisions of this Agreement, Willbros shall: 
  

	2.1	Engineering, Procurement and Construction Management: Perform the Project management, engineering, procurement, construction and construction management for the Project as
described in this Agreement, including in detail at Schedule “B” and the Specifications set forth in Schedule “D”; 

  

	2.2	Manpower and Equipment: Provide Willbros Equipment and Willbros Personnel, including Subcontractors and Vendors, as set forth in more detail in Paragraph 3;

  

	2.3	Compliance: Perform the Work in compliance with the requirements of and provide assistance and documentation to Cheniere as reasonably requested by Cheniere in connection
with those approvals, permits, licenses, and/or other authorizations obtained by Cheniere in accordance with Paragraph 5.1; 

  

	2.4	 Health, Safety and Environmental Performance: Perform the Work in a safe, physically secure and environmentally sound manner and otherwise in compliance with
Cheniere’s health, safety and environmental policies, which are attached hereto as Attachment IX. Cheniere’s provision of such health, safety and environmental policies shall not in any 

  

 A-9 

	 	 
way relieve Willbros of its responsibility regarding safety, health or the environment, and Cheniere, in providing such policies, assumes no liability for
the policies; 

  

	2.5	Authorized Representative: Appoint one (1) or more Willbros Authorized Representative for the duration of the Work; 

  

	2.6	Timeliness and Manner of Performance: Perform all Work in a timely, complete and workmanlike manner in accordance with this Agreement; 

  

	2.7	Drawings and Specifications: Prepare, for Cheniere’s review and approval in accordance with Paragraph 2.8, all necessary Drawings and Specifications for the Project in
accordance with the Applicable Codes and Standards, Applicable Law, Schedule “B”, Schedule “D” and all other requirements within this Agreement; and 

  

	2.8	Review and Approval of Drawings and Specifications: 

  

	 	2.8.1	Over the Shoulder Review: During the development of the Drawings and Specifications, provide Cheniere with the opportunity to perform “over-the-shoulder” reviews of
the design and engineering in progress. Such reviews may be conducted at Willbros’ office located in Tulsa, Oklahoma, at any of its Subcontractors’ offices or remotely by electronic internet access. The reviews may be of progress prints,
computer images, draft documents, working calculations, draft specifications or reports, Drawings, Specifications or other design documents determined by Cheniere. 

  

	 	2.8.2	Submission by Willbros: Submit copies of the Drawings and Specifications to Cheniere for formal review, comment, disapproval and approval in accordance with this Paragraph 2.

  

	 	2.8.3	Review Periods and Cheniere’s Approval: Allow Cheniere up to fifteen (15) days from Cheniere’s receipt of the Drawings and Specifications submitted in
accordance with Paragraph 2.8.2 to issue written comments, proposed changes and/or written approvals or disapprovals of the submission of such Drawings and Specifications to Cheniere. 

  

	 	(i)	If Cheniere does not issue any comments, proposed changes or written approvals or disapprovals within such time period, Willbros may proceed with the development of such Drawings
and Specifications and any construction or procurement relating thereto, but Cheniere’s lack of comments, approval or disapproval shall in no event constitute an approval of the matters received by Cheniere. 

  

	 	(ii)	 In the event that Cheniere disapproves the Drawings or Specifications, Cheniere shall provide Willbros with a written statement of the reasons for such rejection
within the time period required for Cheniere’s response for 

  

 A-10 

	 	 
disapproval of the Drawings or Specifications. Willbros shall provide Cheniere with revised and corrected Drawings or Specifications as soon as possible
thereafter and Cheniere’s rights with respect to the issuing of comments, proposed changes or approvals or disapprovals of such revised and corrected Drawings or Specifications are governed by the procedures specified in this Paragraph 2.8.3;
provided that Willbros shall not be entitled to any extensions of time to the Project Schedule, the Preparation and Material Receipt Commencement Date, the Construction Commencement Date, the Scheduled Mechanical Completion Date, or an adjustment to
the Guaranteed Maximum Price. 

  

	 	(iii)	Upon Cheniere’s written approval of the Drawings and Specifications, such Drawings and Specifications shall be the Drawings and Specifications that Willbros shall use to
construct the Work; provided that Cheniere’s review or approval of any Drawings or Specifications shall not in any way be deemed to limit or in any way alter Willbros’ responsibility to perform and complete the Work in strict accordance
with the requirements of this Agreement, and in the event that there is a discrepancy, difference or ambiguity between the terms of this Agreement and any Drawings or Specifications, the Agreement shall control. Due to the limited time under this
Agreement for Cheniere’s review of the Drawings and Specifications, Willbros’ or its Subcontractors’ or Vendors’ expertise in the Work and Cheniere’s reliance on Willbros to prepare accurate and complete Drawings and
Specifications, Willbros recognizes and agrees that Cheniere is not required or expected to make detailed reviews of the Drawings and Specifications, but instead Cheniere’s review of the Drawings or Specifications may be of only a general,
cursory nature. Accordingly, any reviews or approvals given by Cheniere under this Agreement with respect to any Drawings or Specifications shall not in any way be, or deemed to be, an approval of any Work or Drawings or Specifications not meeting
the requirements of this Agreement, as Willbros has the sole responsibility for performing the Work in accordance with the requirements of this Agreement. 

  

	2.9	 Audit Rights: During the term of this Agreement and for a period of three (3) years after the earlier of Project Completion or termination of this
Agreement, retain full and detailed books, construction logs, Drawings, Specifications, Change Orders, records, daily reports, accounts, payroll records, receipts, statements, electronic files (including schedules, e-mails and CAD), correspondence,
subcontracts and other documents of Willbros, its affiliated companies or their respective Subcontractors and Vendors, which in any way: (a) pertain to the Agreement, including any such documents related to the Work; or (b) relate to
costs, compensation for changes in the Work, or claims of any type by Willbros or its Subcontractors or Vendors (“Books and Records”). Upon five (5) days’ written notice, Cheniere or any of its representatives shall have the
right to audit such Books and Records during such three (3) year period, provided, however, such parties shall not have the right to audit or have audited Books and Records in connection 

  

 A-11 

	 	 
with the internal composition of any compensation that is fixed in amount hereunder such as the composition of unit rates or hourly rates. When requested by
Cheniere, Willbros shall provide the auditors with reasonable access to all such Books and Records, and Willbros Personnel shall cooperate with the auditors to effectuate any audit hereunder. The auditors shall have the right to copy all such Books
and Records. Willbros shall include audit provisions identical to this Paragraph 2.9 in all subcontracts and purchase orders with Subcontractors and Vendors. Willbros shall maintain all Books and Records in accordance with generally accepted
accounting principles applicable in the United States. Willbros will not charge for any costs incurred by it in assisting Cheniere with audits performed pursuant to this Paragraph 2.9. Willbros obligations under this Paragraph 2.9 shall survive the
termination of this Agreement. 

 3. WILLBROS PERSONNEL AND EQUIPMENT 
  

	3.1	Key Personnel: Willbros Personnel shall be provided in sufficient numbers, and shall be competent and fully qualified to execute the Work. Willbros shall submit to
Cheniere’s Authorized Representative an updated organization chart of key Project personnel from Willbros’ or its Subcontractors’ or Vendors’ organization (“Key Personnel” or “Key Persons”) who shall be
assigned to the Work, such organization chart to be in the form of and attached as Attachment VIII. Key Personnel shall, unless otherwise expressly stated in such organization chart, be devoted full-time to the Work for the entire duration of
the Project, and Key Personnel shall not be removed or reassigned without Cheniere’s prior written approval. Cheniere shall have the right, but not the obligation, at any time to request that Willbros replace any Key Person with another
employee acceptable to Cheniere. In such event, Willbros shall replace such Key Person without additional expense to Cheniere. 

  

	3.2	Willbros Equipment: Willbros Equipment shall be suitable for the performance of the Work, in good repair and otherwise comply with the terms of this Agreement.
Notwithstanding anything to the contrary contained in this Agreement, Willbros shall be responsible for repair, damage to or destruction or loss of, from any cause whatsoever, all Willbros Equipment. Willbros shall require that all insurance
policies (including policies of Willbros and all Subcontractors and Vendors) in any way relating to such Willbros Equipment include clauses stating that each underwriter will waive all rights of recovery, under subrogation or otherwise, against the
Cheniere Group. 

  

	3.3	 Subcontractors and Vendors: Cheniere acknowledges and agrees that Willbros intends to have portions of the Work accomplished by Subcontractors or Vendors
pursuant to written subcontracts or purchase orders between Willbros and such Subcontractors and Vendors, and that such Subcontractors and Vendors may have certain portions of the Work performed by lower tier subcontractors or vendors. All
Subcontractors and Vendors shall be reputable, qualified firms with an established record of successful performance in their respective trades performing identical or substantially similar work. All contracts with Subcontractors and Vendors shall be
consistent with the terms or provisions of this Agreement. No Subcontractor or Vendor is intended to be or shall be 

  

 A-12 

	 	 
deemed a third party beneficiary of this Agreement. Willbros shall be fully responsible to Cheniere for the acts or omissions of Subcontractors and Vendors
and of persons directly or indirectly employed by either of them, as Willbros is for the acts or omissions of persons directly employed by Willbros. The Work of any Subcontractor or Vendor shall be subject to inspection by Cheniere to the same
extent as the Work of Willbros. Nothing contained herein shall (i) create any contractual relationship between any Subcontractor or Vendor and Cheniere, or (ii) obligate Cheniere to pay or cause the payment of any amounts to any
Subcontractor or Vendor. Willbros shall, within thirty (30) days prior to the selection of any Subcontractor or Vendor, notify Cheniere in writing of the selection of such Subcontractor or Vendor and inform Cheniere generally what portion of
the Work such Subcontractor or Vendor is performing. 

  

	3.4	Bidding of Subcontracts and Purchase Orders: As part of Willbros’ performance of the Work on an “open book basis”, Willbros shall provide all necessary
services related to the bidding of subcontracts and purchase orders for the construction and procurement components of the Work, including the following: (a) preparing lists of prospective bidders for review by Cheniere; (b) preparing
appropriate bid documents, including proposed forms of subcontract and purchase orders; (c) establishing bid schedules; (d) advertising for bids and developing bidder interest; (e) furnishing information concerning the Project to
prospective bidders; (f) conducting pre-bid conferences; (g) receiving bids, as described below, and analyzing bids and making recommendations to Cheniere regarding bid awards; (h) investigating the acceptability and responsibility of
lower-tiered Subcontractors and Vendors proposed by any Subcontractor or Vendor and advising Cheniere of such evaluations; (i) negotiating with Subcontractors and Vendors concerning any matter related to the Project; and (j) providing such
other services required by Cheniere with respect to the bidding process. Willbros shall require bidders to submit their sealed bids directly to Willbros, and Willbros shall forward copies of such bids to Cheniere. Willbros shall require bidders for
the construction component of the Work to submit their sealed bids directly to Cheniere and copies of such bids to Willbros. The receipt of the proposed bidders list by Cheniere shall not require Cheniere to investigate the qualifications of
prospective bidders, nor shall it waive the right of Cheniere to later object to or reject any proposed Subcontractors or Vendors. 

  

	3.5	Cheniere Approval of Subcontractors and Vendors: 

  

	 	3.5.1	Approved Subcontractors and Vendors List: Attachment VII sets forth a list of Subcontractors and Vendors that Willbros and Cheniere have agreed are approved
Subcontractors and Vendors for the performance of that stated portion of the Work specified in Attachment VII. Approval by Cheniere of any Subcontractors or Vendors does not relieve Willbros of any responsibilities under this Agreement.
Unless Cheniere otherwise approves, each prospective bidder list shall contain at least three (3) Subcontractors or Vendors from the Approved Subcontractors and Vendors List in Attachment VII. 

  

 A-13 

	 	3.5.2	Additional Proposed Subcontractors and Vendors: In the event that Willbros is considering the selection of a Subcontractor or Vendor not listed on Attachment VII,
Willbros shall (i) notify Cheniere of its proposed Subcontractor or Vendor as soon as possible during the selection process, including clearly identifying such proposed Subcontractor or Vendor on the list of prospective bidders provided in
accordance with Paragraph 3.4, and furnish to Cheniere all information reasonably requested by Cheniere with respect to Willbros’ selection criteria, and (ii) notify Cheniere no less than seven (7) business days prior to the execution
of a subcontract or purchase order with a Subcontractor or Vendor not listed on Attachment VII. Cheniere shall have the discretion, not to be unreasonably exercised, to reject any proposed Subcontractor or Vendor not listed on Attachment
VII at any time. Willbros shall not enter into any subcontract or purchase order with a proposed Subcontractor or Vendor that is rejected by Cheniere in accordance with the preceding sentence. Cheniere shall undertake in good faith to review the
information provided by Willbros with respect to such proposed Subcontractor or Vendor expeditiously and shall notify Willbros of its decision to accept or reject a proposed Subcontractor or Vendor as soon as practicable after such decision is made.
Failure of Cheniere to accept a proposed Subcontractor or Vendor within seven (7) business days shall be deemed to be a rejection of such Subcontractor or Vendor. 

 4. WORK SITE RESPONSIBILITIES 
  

	4.1	Land Acquisition Plan: Willbros shall provide reasonable assistance to Cheniere, as requested by Cheniere in writing, in finalizing Cheniere’s land acquisition plan as
necessary to permit land activities for the Project to proceed in accordance with the FERC Certificate and in accordance with Paragraph 5.2. Such plan may include required rights of way, access roads, materials and equipment storage facilities,
office sites, vehicle parking areas, temporary electrical supply locations and trash collection areas, including proposed locations for each. 

  

	4.2	Provision of Facilities: Willbros shall provide warehousing, offices, storage and related utilities in accordance with the terms of this Agreement and the FERC Certificate
for Willbros Equipment and such other materials and equipment to be incorporated into the Work. 

  

	4.3	Maintenance of Work Sites: Willbros shall, to Cheniere’s satisfaction, at all times keep the Work Site free from all waste materials or rubbish caused by the activities
of Willbros or any of its Subcontractors or Vendors. Without limitation of the foregoing or limiting Willbros’ obligations, Willbros shall clean up all such waste materials or rubbish at Cheniere’s request with reasonable notice.

  

	4.4	 Compliance with Real Property Interests and Other Work Site Restrictions: Willbros shall, in the performance of the Work, comply, and cause all
Subcontractors and Vendors to comply, with any agreement governing any easement, lease, right-of-way or other 

  

 A-14 

	 	 
property interests that affect or govern the Work Site or any other real property used for the purposes of completing the Work, including any line list,
insurance or indemnification restrictions or obligations therein, to the extent such easement, lease, right-of-way or other property interests relate to the performance of the Work (but only to the extent that such indemnification restrictions and
obligations are consistent with Willbros indemnification obligations agreed to herein). In addition, Willbros shall comply with any one-call requirements imposed by Applicable Law (including local law) and coordinate with owners or operators of all
third-party utilities, including those crossed by the Project or otherwise situated within the Work Site or affected by the Work. Cheniere shall provide Willbros with copies of all relevant portions of the agreements governing such easement, lease,
right-of-way, and other property interests to the extent that such agreements impose restrictions or obligations on Willbros pursuant to this Paragraph 4.4. To the extent that such agreements require Willbros to procure insurance in addition to or
in amounts in excess of that insurance required by this Agreement, the Willbros shall be entitled a Change Order increasing the Guaranteed Maximum Price to cover the cost of such additional insurance. 

  

	4.5	Coordination of Work: Willbros acknowledges that Cheniere and other consultants and contractors may be working at the Work Site during the performance of this Agreement and
the Work or use of certain facilities may be interfered with as a result of such concurrent activities, and Willbros agrees to coordinate the performance of the Work with Cheniere and such other consultants and contractors performing work at the
Work Site so as not to materially interfere with Cheniere or its other consultants or subcontractors performing work at the Work Site. 

 5. CHENIERE’S OBLIGATIONS 
 In close cooperation and coordination with Willbros, and subject to the terms and conditions of the
Agreement, Cheniere shall: 
  

	5.1	Licenses and Permits: Provide, or cause to be provided, all approvals, permits, licenses (other than Willbros’ or its Subcontractors’ or Vendors’ operating and
professional licenses, including road bonding) and/or other authorizations necessary for the Project from any Governing Authority, including the FERC Certificate and all environmental agencies. 

  

	5.2	Work Site Access: Secure legal and reasonable access to the Work Site, in accordance with the FERC Certificate, as necessary to permit Willbros to commence Work in accordance
with this Agreement by obtaining the rights of way, pipe yards, ware yards, and all other land rights or property interests necessary for the Work, all in accordance with Cheniere’s land acquisition plan. 

  

	5.3	 Cheniere Provided Items: Cheniere shall provide: (i) hydrostatic test water; (ii) natural gas or nitrogen and personnel to determine the
achievement of Start-up in accordance with Paragraphs 1.57 and 8.2; and (iii) environmental inspection services during 

  

 A-15 

	 	 
construction Work. In addition, Cheniere shall provide to Willbros the following preliminary drawings which shall be updated by Willbros in accordance with
this Agreement: (y) preliminary drawings submitted to FERC, indicated by drawing numbers CH-5763-D-1103 (Sheets 1 to 6), Rev. 0 and titled “Proposed 42-inch Natural Gas Pipeline, Sabine Pass Pipeline Project, FERC Alignment Sheet,”
and (z) preliminary alignment drawings, indicated by drawing numbers CH-5763D-1101 to 1115, Rev. 1 and titled “Cheniere, Sabine to Johnson’s Bayou, Cameron Parish, Louisiana.” 

  

	5.4	Payment: Remunerate Willbros as required by the Agreement. 

  

	 	5.4.1	Contract Amount: Subject to additions and deductions by Change Order, Cheniere shall pay Willbros for performance of the Work to be performed by Willbros for the Project as
described in this Agreement and Schedule “B”, the “Contract Amount” consisting of (i) the Cost of the Work, (ii) the Willbros Management Fee, (iii) Contingency Costs, and (iv) Louisiana sales and use
taxes applicable to permanent materials and equipment to be incorporated into the Project. The “Cost of the Work” shall mean those costs necessarily incurred by Willbros in good faith in the proper performance of the Work.

  

	 	5.4.2	 Taxes: The Guaranteed Maximum Price includes any and all taxes, assessments, levies, duties, fees, charges and withholding of any kind or nature whatsoever
and howsoever described, including value-added, sales and use taxes (except as indicated herein), gross receipts, license, payroll, environmental, profits, premium, franchise, property, excise, capital stock, import, stamp, transfer, employment,
occupation, generation, privilege, utility, regulatory, energy, consumption, lease, filing, recording and activities taxes, levies, duties, fees charges, imposts and withholding, together with any and all penalties, interests and additions thereto
in any way related to the Work (collectively, “Taxes”), but not including Louisiana sales and use taxes applicable to permanent materials and equipment to be incorporated into the Project, the cost of which is not subject to the Guaranteed
Maximum Price. With each invoice that requests reimbursement for Louisiana sales and use taxes applicable to permanent materials and equipment to be incorporated into the Project, Willbros shall separately list in the invoice such Louisiana sales
and use taxes. Subject to the other provisions of this Agreement, Cheniere shall remit to Willbros the payment of such Louisiana sales and use taxes within the time allowed for payment of invoices under this Agreement. Willbros shall be responsible
for paying to the applicable Governing Authority all Taxes and Louisiana sales and use taxes applicable to permanent materials and equipment to be incorporated into the Project owed under Applicable Law with respect to the Work. IF AND TO THE EXTENT
CHENIERE HAS PAID TO WILLBROS THE APPLICABLE TAXES AND LOUISIANA SALES AND USE TAXES APPLICABLE TO PERMANENT MATERIALS AND EQUIPMENT TO BE INCORPORATED INTO THE PROJECT REQUIRED UNDER THIS PARAGRAPH, WILLBROS SHALL INDEMNIFY, DEFEND AND HOLD
HARMLESS THE CHENIERE GROUP FROM AND AGAINST ANY CLAIMS 

  

 A-16 

	 	 
BY ANY GOVERNING AUTHORITY FOR THE NON-PAYMENT OF SUCH TAXES AND SUCH LOUISIANA SALES AND USE TAXES. 

  

	 	5.4.3	Invoicing: Willbros shall submit invoices to Cheniere as follows: 

  

	 	(i)	twice per month for Project management, engineering and drafting, procurement services, and construction management services performed during the previous invoicing period. Charges
shall be accumulated and invoiced on a rate reimbursable basis reflecting man-hours expended as described in Paragraph 1.2 of Attachment I to the Letter Agreement; 

  

	 	(ii)	for permanent materials as set forth in Paragraph 1.3 of Attachment I to the Letter Agreement; 

  

	 	(iii)	for the construction component of the Work as set forth in Paragraph 1.4 of Attachment I to the Letter Agreement; 

  

	 	(iv)	for the Willbros Management Fee properly allocable to the completed Work. The Willbros Management Fee allocable to the completed Work shall be determined by multiplying the
percentage completion of the Work by the total amount of the Willbros Management Fee payable to Willbros for the Project; and 

  

	 	(v)	for Willbros’ portion of any Shared Savings upon Project Completion. 

  

	 	5.4.4	Invoice Format: Invoices shall be complete with sufficient detail and itemized to facilitate Cheniere’s confirmation and approval. Willbros’ invoices shall be in a
format and supported by such documentation as required by Cheniere. Without limitation of the foregoing, Willbros shall, with each invoice, submit payrolls, petty cash accounts, receipted invoices or invoices with check vouchers attached, and any
other evidence required by Cheniere to demonstrate that cash disbursements already made by Willbros on account of the Cost of the Work equal or exceed (i) progress payments already received by Willbros; less (ii) that portion of those
payments attributable to the Willbros Management Fee; plus (iii) payrolls for the period covered by the present invoice. Invoices shall show the percentage of completion of each portion of the Work as of the end of the period covered by the
invoice. The percentage of completion shall be the lesser of: (1) the percentage of that portion of the Work which has actually been completed; or (2) the percentage obtained by dividing (a) the expense that has actually been incurred
by Willbros on account of that portion of the Work for which Willbros has made or intends to make actual payment prior to the next invoice by (b) the share of the Guaranteed Maximum Price allocated to that portion of the Work in the Schedule of
Values. 

  

 A-17 

	 	5.4.5	Payment Terms: Cheniere shall pay Willbros all undisputed amounts due hereunder within fifteen (15) days after receipt of a complete and accurate invoice for Work that
is satisfactorily completed during that period. 

  

	 	5.4.6	Lien and Claim Waivers: Each progress invoice shall be accompanied by a fully executed Willbros’ Interim Lien and Claim Waiver in the form of Attachment X – Part
1, a fully executed Interim Lien and Claim Waiver in the form of Attachment X – Part 3 for each Subcontractor and Major Vendor, and such other evidence satisfactory to Cheniere to ensure that all amounts owed in connection with
performance of this Agreement, including amounts owed to all Subcontractors and Vendors, have been paid. Waivers of liens and claims, however, will not be required from Subcontractors or Vendors until they have performed Work or furnished materials
or equipment, and Willbros, Subcontractors and Major Vendors will be required to submit waivers of liens and claims only if they have performed Work or furnished materials or equipment not covered by a previous waiver. Receipt of all Interim Lien
and Claim Waivers under this Paragraph 5.4.6 or all Final Lien and Claim Waivers required to meet the requirements of Paragraph 1.49, as applicable, is a condition precedent to payment of any amounts under an invoice. 

  

	 	5.4.7	Final Invoice: Prior to submission of a final invoice, Willbros shall perform an audit to determine the total Cost of the Work for the Project. Such audit shall also take
into consideration Contingency Costs expended and the Willbros Management Fee in order to calculate the Actual Contract Amount in accordance with Paragraph 2.2 of Attachment I to the Letter Agreement. Willbros shall provide a copy of such
audit report to Cheniere upon submission of Willbros’ final invoice. Cheniere’s accountants will review and report in writing on Willbros final audit within thirty (30) days after delivery thereof by Willbros. If Cheniere’s
accountants report the Cost of the Work and Contingency Costs as substantiated by Willbros final audit to be less than claimed by Willbros, and Willbros disagrees with Cheniere’s accountants reporting of the Cost of the Work and Contingency
Costs, Willbros has the right, within seven (7) days of its receipt of the Cheniere’s accountants’ report, to submit the Dispute for resolution in accordance with Paragraph 14. If Willbros fails to submit the Dispute within such seven
(7) day period, Willbros shall be deemed to have agreed with Cheniere’s accountants report on the Cost of the Work and Contingency Costs. Final payment shall not be made until resolution of a Dispute under this Paragraph 5.4.7.

  

	 	5.4.8	 Unperformed Obligations: Project Completion and payments made hereunder shall not in any way release Willbros or any surety of Willbros or its Subcontractors
from any unperformed obligations of the Agreement, including Warranties, compliance with the Agreement, liabilities for which insurance is required or any other responsibility of Willbros, including the payment of any and 

  

 A-18 

	 	 
all fines and penalties assessed as a result of Willbros’ failure to comply with Applicable Law or Applicable Codes and Standards.

  

	 	5.4.9	Withholding: In addition to retainage and amounts withheld that are in dispute, Cheniere may, in addition to any other rights at law, in equity or under this Agreement,
withhold amounts otherwise due by Cheniere to Willbros without payment of interest on account of: (a) Defective Work not remedied by Willbros in accordance with Paragraph 12; (b) the filing of claims or liens or evidence indicating the
probable filing of claims or liens against Cheniere, the Project or the Work; (c) failure of Willbros to pay amounts when due for labor, services or material used by Willbros in performing the Work or amounts due to Subcontractors or Vendors as
required in their respective subcontracts and purchase orders; (d) the assessment of any fines or penalties against Cheniere as a result of Willbros’ failure to comply with Applicable Law or Applicable Codes and Standards; or (e) any
other circumstance permitted under this Agreement. If and when the cause, or causes, for withholding any such payment shall be remedied or removed and satisfactory evidence of such remedy or removal has been presented to Cheniere, the payments
withheld shall be made to Willbros in the next invoice and if the final invoice has been paid, within thirty (30) days of such remedy or removal. 

  

	 	5.4.10	Payment Account Number: Payments to Willbros under this Agreement shall be made by wire transfer to: 

  

	
	 Southwest Bank of Texas

	 Houston, Texas

	 ABA#: 113-011-258

	 Beneficiary: Willbros USA, Inc.

	 Account Number: 127736

  

	 	5.4.11	Address for Invoicing: Willbros shall submit invoices for payment to: 

  

			
	 Cheniere Sabine Pass Pipeline

	 717 Texas Avenue, Suite 3100

	 Houston, Texas 77002

	 Telephone:
	  	 (713) 659-1361

	 E Mail
	  	 abartz@cheniere.com

	 Facsimile:
	  	 (713) 659-5459

	 Attention:
	  	 Mr. Allan Bartz

	
	 Or such other addressee and location as Cheniere may direct in writing.

  

	 	5.4.12	 Payment of Shared Savings: Willbros shall be paid its share of the Shared Savings within thirty (30) days of settlement and verification thereof by the

  

 A-19 

	 	 
Parties following Cheniere’s receipt of a final invoice and accounting report from Willbros in accordance with Paragraphs 5.4.4 and 5.4.7.

  

	 	5.4.13	Schedule of Values: Attachment IV of the Letter Agreement sets forth the schedule of values allocating the entire Guaranteed Maximum Price among the various portions
of the Work as of the Effective Date of the Agreement (“Schedule of Values”) to be used as a basis for reviewing the invoices. Willbros shall periodically, upon award of various components of the Work to Subcontractors and Vendors, submit
to Cheniere for Cheniere’s written approval an updated Schedule of Values allocating the entire Guaranteed Maximum Price among the various portions of the Work, except that the Willbros Management Fee shall be shown as a separate line item. The
updated Schedule of Values shall be prepared in such form and supported by such data to substantiate its accuracy as Cheniere may require. Each Cheniere-approved, updated Schedule of Values shall be incorporated into this Agreement by Change Order.

 6. WORK PLAN AND REPORTS 
  

	6.1	Time for Performance: Willbros shall commence performance of the Work upon the Effective Date and shall perform the Work in accordance with the Project Schedule set forth in
this Paragraph 6 and in Schedule “F”. TIME IS OF THE ESSENCE with respect to Willbros’ performance of the Work. Willbros may not commence a portion of the Work prior to the relevant commencement date, if any, listed below:

  

	 	6.1.1	Willbros shall commence Work related to ware yard preparation and material receipt at the Work Site no earlier than January 01, 2007 (“Preparation and Material Receipt
Commencement Date”). The Preparation and Material Receipt Commencement Date shall only be adjusted by Change Order as provided under this Agreement. 

  

	 	6.1.2	Willbros shall commence Work related to the construction of the Project at the Work Site no earlier than April 01, 2007 (“Construction Commencement Date”). The
Construction Commencement Date shall only be adjusted by Change Order as provided under this Agreement. 

  

	 	6.1.3	Willbros shall achieve Mechanical Completion of the Project no later than September 30, 2007 (“Scheduled Mechanical Completion Date”) based on an April 1, 2007,
release for construction. The Scheduled Mechanical Completion Date shall only be adjusted by Change Order as provided under this Agreement. 

  

	6.2	 Work Plan: On or before February 28, 2006, Willbros shall prepare and submit to Cheniere’s Authorized Representative for review and written
approval, a detailed critical path method schedule in a format approved by Cheniere (“Work Plan”). The Work Plan shall be based on and consistent with the Project Schedule, including the Preparation and Material Receipt Commencement Date,
the Construction Commencement Date and the 

  

 A-20 

	 	 
Scheduled Mechanical Completion Date, shall show the method and order in which Willbros shall perform the Work, its subcontracting plan, and any other
information that Cheniere may consider useful. The Work Plan shall represent Willbros’ best judgment as to how it shall achieve Mechanical Completion by the Scheduled Mechanical Completion Date, and shall be a detailed graphic representation of
all significant aspects of the Work showing Willbros’ plans for performance of the Work. Without limitation of the foregoing, the Work Plan shall include separate activities for each portion of the Work, show the duration, early/late start
dates, early/late finish dates and available float for each activity, show activity number, activity description and responsible Subcontractor or Vendor, and show an uninterrupted critical path from commencement of the Work through Project
Completion. 

  

	6.3	Updated Work Plan: The Work Plan shall be used as the basis for progress reporting, schedule control and schedule forecasting. As reasonably requested by Cheniere, Willbros
shall revise the Work Plan to include the effect of Change Orders and Amendments and to reflect actual Work in progress as agreed with Cheniere, provided, however, Willbros may not modify the Preparation and Material Receipt Commencement Date, the
Construction Commencement Date or the Scheduled Mechanical Completion Date without a Change Order being executed in accordance with this Agreement. Each updated Work Plan shall provide the same details and form as required of the Work Plan. Willbros
shall prepare schedule and cash flow forecasts on a monthly basis or as requested by Cheniere that reasonably predict the date for Mechanical Completion of the Project. Willbros shall notify Cheniere of any anticipated or actual slippage in the
performance of the Work as compared to the Work Plan. Willbros shall provide to Cheniere weekly reports, monthly summaries of such reports, and upon request, all other relevant information concerning any circumstance or condition affecting the Work.

  

	6.4	Progress Meetings: Work progress meetings between Authorized Representatives shall be held monthly between Cheniere and Willbros. 

  

	6.5	 Recovery: If Willbros is responsible for any delays in the time and/or sequence of the performance of the Work that is on the critical path of the Work Plan,
Willbros shall on its own initiative or at Cheniere’s written directive, employ such additional forces, obtain such additional equipment, employ such additional supervision, pay such additional overtime wages, and use such priority freight as
may be required to bring the Work back on schedule. If Willbros’ progress is more than fourteen (14) days behind the critical path of the Work Plan, Cheniere may, without prejudice to any other remedies available to it under this
Agreement, also require in writing that Willbros submit, within two (2) days of Cheniere’s written notice and for Cheniere’s approval, a recovery plan to Cheniere detailing Willbros’ proposal for bringing the Work back on
schedule and that the sequence of the performance of the Work be changed. In no event shall such costs to bring the Work back on schedule cause the Guaranteed Maximum Price to be exceeded. This Paragraph 6.5 shall not be construed to require that
Cheniere give Willbros a written notice to perform any of the acts listed herein, and the Parties agree that Cheniere’s 

  

 A-21 

	 	 
failure to give such written notice to Willbros shall not in any way relieve Willbros of its obligation to perform the Work within the times set forth in the
Project Schedule. 

  

	6.6	Acceleration: Even if the Work is otherwise in compliance with the Work Plan, Cheniere may, at any time, direct Willbros to accelerate the Work by, among other things,
establishing additional shifts, paying or authorizing overtime or providing additional equipment. In the event of this directive, Cheniere’s sole liability to Willbros shall be to pay Willbros for any documented costs clearly and solely
attributable to such acceleration. Such costs may include any shift differential, premium, or overtime payments to workers or field supervisors and other employees of Willbros dedicated to the Work on a full-time basis actually incurred over and
above Willbros’ normal rates, overtime charges for equipment, amounts to account for lost efficiency of workers and other costs agreed upon by Cheniere and Willbros in writing. Any adjustment to the Guaranteed Maximum Price resulting from
Cheniere’s directive to accelerate the Work shall be implemented by Change Order. 

 7. INSPECTION AND TESTING

  

	7.1	QA/QC Plan: On or before March 31, 2006, Willbros shall submit to Cheniere’s Authorized Representative, for review and written approval thereof, a quality assurance
and quality control plan for materials procurement and for construction (“QA/QC Plan”). Cheniere’s review and approval of the QA/QC Plan shall in no way relieve Willbros of its responsibility for performing the Work in compliance with
this Agreement. 

  

	7.2	Willbros’ Inspection and Testing of Work: Willbros shall inspect and test the overall and component parts of the Work, including that of its Subcontractors or Vendors,
to ensure conformity of such Work with Applicable Codes and Standards, and all other obligations within this Agreement. 

  

	7.3	Cheniere Inspection of Work: All Work shall be subject to inspection by Cheniere or its designee at all times and at Cheniere’s own expense, to determine whether the
Work conforms to the requirements of this Agreement. Willbros shall furnish Cheniere with access to all locations where Work is in progress, including locations not on the Work Site such as locations from where equipment and material are being
obtained, including pipe fabrication and coating and factory testing of mainline valves. 

  

	7.4	 Correction of Work Prior to Start-up: If, in the judgment of Cheniere, any Work is Defective or any Work is determined to be Defective as a result of the
testing and inspections performed pursuant to Paragraph 7.2, then Willbros shall, at its own expense, promptly correct such Defective Work, whether by repair, replacement or otherwise. Subject to Willbros’ right to pursue a Dispute under
Paragraph 14, the decision of Cheniere shall be conclusive as to whether the Work is conforming or Defective, and Willbros shall comply with the instructions of Cheniere in all such matters while pursuing any such Dispute. If it is later determined
that the Work was not Defective, then Cheniere shall reimburse Willbros for all costs incurred in connection with such repair or 

  

 A-22 

	 	 
replacement and a Change Order shall be issued for such amount and shall address any impact the repair or replacement may have had on the Project Schedule.
If Willbros fails, after a reasonable period of time not to exceed five (5) days, to repair or replace any Defective Work, or to commence to repair or replace any Defective Work and thereafter continue to proceed diligently to complete the
same, then Cheniere may repair or replace such Defective Work and the expense thereof shall be paid by Willbros. 

  

	7.5	Notice to Cheniere and Cost of Disassembling: Willbros shall advise Cheniere’s Authorized Representative of tests to be witnessed sufficiently in advance to enable him
or his designee to attend and witness such test at Cheniere’s expense. Willbros shall likewise advise Cheniere’s Authorized Representative in advance of any critical component of the Work to be closed or covered. If such action is taken by
Willbros before an opportunity to inspect or witness has been provided to Cheniere, it must, if required by Cheniere, be opened or uncovered for inspection or witnessing and recovered at Willbros’ expense. The cost of disassembling, dismantling
or making safe finished Work for the purpose of inspection, other than as set forth above, and reassembling such portions (and any delay associated therewith) shall be borne by Cheniere if such Work is found to conform with the requirements of this
Agreement and by Willbros if such Work is found to be Defective. 

  

	7.6	No Obligation to Inspect: Cheniere’s right to conduct inspections under this Paragraph 7 shall not obligate Cheniere to do so. Neither the exercise of Cheniere of any
such right, nor any failure on the part of Cheniere to discover or reject Defective Work shall be construed to imply an acceptance of such Defective Work or a waiver of such Defect. 

 8. COMPLETION AND START-UP 
  

	8.1	Mechanical Completion: Willbros shall comply with all requirements for Mechanical Completion, including as set forth in the definition of the term Mechanical Completion and
elsewhere in this Agreement. When Willbros believes the Work is Mechanically Complete, Willbros shall certify to Cheniere in writing in the form of the Mechanical Completion Certificate attached hereto as Attachment III that all of the
requirements for Mechanical Completion of the Work have occurred, including all documentation required to establish that the requirements for Mechanical Completion have been met. Within seven (7) days after receipt of such notice Cheniere shall
inspect the Work and either accept the Work as being Mechanically Complete (which acceptance shall be evidenced by Cheniere’s signature on such Mechanical Completion Certificate), or specify the Exception Items which must be completed to
achieve Mechanical Completion in a written notice to Willbros. Upon completion or correction of such Exception Items, Willbros shall so advise Cheniere. Within seven (7) days after receipt of such notice, Cheniere shall either accept the Work
as being Mechanically Complete in the manner set forth above, or notify Willbros in writing of still unfinished or uncorrected Exception Items. If Exception Items remain unfinished or uncorrected, the foregoing procedure shall be repeated until the
Work is Mechanically Complete. 

  

 A-23 

	8.2	Start-up: Willbros shall comply with all requirements needed to achieve Start-up, including as set forth in the definition of the term Start-up and elsewhere in this
Agreement. When Willbros believes Start-up has been achieved, Willbros shall certify to Cheniere in writing in the form of the Start-up Certificate attached hereto as Attachment V that all of the requirements for achieving Start-up have
occurred, including all documentation required to establish that the requirements for Start-up have been met. Within seven (7) days after receipt of such notice Cheniere shall inspect the Work and either accept the Work as having achieved
Start-up (which acceptance shall be evidenced by Cheniere’s signature on such Start-up Certificate), or specify the Exception Items which must be completed to achieve Start-up in a written notice to Willbros. Upon completion or correction of
such Exception Items, Willbros shall so advise Cheniere. Within seven (7) days after receipt of such notice, Cheniere shall either approve the Start-up of the Work in the manner set forth above, or notify Willbros in writing of still unfinished
or uncorrected Exception Items. If Exception Items remain unfinished or uncorrected, the foregoing procedure shall be repeated until Start-up is achieved. Notwithstanding the foregoing, if Cheniere has not commenced the introduction of either
natural gas or nitrogen in accordance with Paragraph 1.57 within thirty (30) days of achievement of Mechanical Completion, then Start-up shall be deemed achieved upon the expiration of such thirty (30) day period, provided that Willbros
has fully satisfied all other requirements for Start-up. 

  

	8.3	Project Completion: Willbros shall comply with all requirements for Project Completion, including as set forth in the definition of the term Project Completion and elsewhere
in this Agreement. When Willbros believes it has completed all obligations under this Agreement to achieve Project Completion, Willbros shall certify to Cheniere in writing in the form of the Project Completion Certificate as attached hereto as
Attachment IV that all of the requirements for achieving Project Completion have occurred, including all documentation required to establish that the requirements of Project Completion have been met. Within seven (7) days after receipt
of such notice Cheniere shall inspect the Work and either accept that Project Completion has been achieved (which acceptance shall be evidenced by Cheniere’s signature on such Project Completion Certificate), or specify the Exception Items
which must be completed to achieve Project Completion in a written notice to Willbros. Upon completion or correction of such Exception Items, Willbros shall so advise Cheniere. Within seven (7) days after receipt of such notice, Cheniere shall
either accept the Work as having achieved Project Completion in the manner set forth above, or notify Willbros in writing of still unfinished or uncorrected Exception Items. If Exception Items remain unfinished or uncorrected, the foregoing
procedure shall be repeated until Project Completion is achieved. 

  

	8.4	 No Waiver: No acceptance by Cheniere of any or all of the Work or any other obligations of Willbros under this Agreement, including acceptance of Mechanical
Completion, Start-up or Project Completion, nor any payment made hereunder, whether an interim or final payment, shall in any way release Willbros or any surety of Willbros or its Subcontractors from any obligations or liability pursuant to this
Agreement, including obligations with respect to unperformed obligations of this Agreement, obligations 

  

 A-24 

	 	 
regarding any remediation or other Work required pursuant to Paragraph 12, correction of any Work that does not conform to the requirements of the Agreement
or other Warranty obligations, and any liabilities for which insurance is required or any other responsibility of Willbros, including the payment of any and all fines and penalties assessed as a result of Willbros’ failure to comply with
Applicable Law. 

 9. CHANGES 
  

	9.1	Change Orders Requested by Cheniere: At any time upon written notice to Willbros from Cheniere, and without notice to the sureties, if any, Cheniere may advise Willbros to
make or agree with Willbros that there has been a Change to the Work, including the time and/or sequence of performance, or the conditions affecting the Work. All Work involved in a Change, as directed by a Change Order, shall be performed in
accordance with the terms and conditions of the Agreement and shall not otherwise affect the existing rights or obligations of the Parties (except as may be expressly stated in a Change Order). Cheniere shall specify, in the Change Order, the amount
and nature of Work to be done or omitted, the materials to be used and the equipment to be furnished. Willbros shall perform the Work as changed without delay. 

  

	9.2	Change Order Format: A Change in the Work shall be set forth in writing in a Change Order, using the form provided in Attachment VI, and signed by both Parties. Change
Orders shall include the adjustment, if necessary, in the Preparation and Material Receipt Commencement Date, the Scheduled Mechanical Completion Date, Construction Commencement Date or the Guaranteed Maximum Price. 

  

	9.3	Change Orders Act as Accord and Satisfaction: The Parties agree that Change Orders executed by Cheniere and Willbros shall constitute a full and final settlement and accord
and satisfaction of all effects of the Change upon any and all respects of this Agreement and the Work and shall compensate Willbros fully. Willbros expressly waives and releases any and all right to make a claim or demand or to take any action or
proceeding for any other consequences arising out of, relating to, or resulting from the Change reflected in the Change Order, whether the consequences result directly or indirectly from the Change reflected in that Change Order.

  

	9.4	 Adjustment Only Through Change Order: Willbros shall not perform a Change of any kind, except as authorized in a Change Order. Adjustments to the Guaranteed
Maximum Price, the Preparation and Material Receipt Commencement Date, the Construction Commencement Date or the Scheduled Mechanical Completion Date shall only be made by Change Order. No course of conduct or dealings between the Parties, nor
express or implied acceptance of additions, deletions, suspensions or modifications to this Agreement, the Drawings or the Specifications, including any Work, and no claim that Cheniere has been unjustly enriched by any such addition, deletion,
suspension or modification of this Agreement, the Drawings or the Specifications, whether or not there is in fact any such unjust enrichment, shall be the basis for any claim for an adjustment in the Guaranteed Maximum Price, the Preparation and
Material Receipt Commencement 

  

 A-25 

	 	 
Date, the Construction Commencement Date, the Scheduled Mechanical Completion Date or any other obligations of Willbros under this Agreement.

  

	9.5	Change Orders Requested by Willbros: Willbros shall give written notice to Cheniere of any requests, claims or proposals for adjustments to the Work, the Guaranteed Maximum
Price, the Preparation and Material Receipt Commencement Date, the Construction Commencement Date or the Scheduled Mechanical Completion Date for Changes directed by Cheniere or for circumstances otherwise permitted by this Agreement within the time
frame and in accordance with Paragraph 14.1. 

  

	9.6	Change Order Compensation: The cost or credit to Cheniere resulting from a Change in the Work shall in each instance be determined in accordance with one of more of the
following methods and specified in the Change Order: (i) by mutual acceptance of a properly itemized lump sum amount; or (ii) for Project management, engineering and drafting, procurement services and construction management services, by
unit prices or hourly rates set forth in Attachment II of the Letter Agreement or otherwise agreed upon by the Parties; or (iii) for construction work performed by Willbros RPI, Inc. (if such entity is the selected construction
Subcontractor), by unit prices or hourly rates set forth in Attachment III of the Letter Agreement or otherwise agreed upon by the Parties. If any of the Changes provided for in a Change Order increase the lump sum construction costs within
the Guaranteed Maximum Price, such increase shall be subject to Cheniere’s right to retainage as set forth in Paragraph 1.4.1 of the Letter Agreement. 

 10. INDEMNITY, LIENS AND PATENTS 
  

	10.1	General Indemnifications: Notwithstanding any other provision to the contrary, Cheniere and Willbros agree as follows: 

  

	 	10.1.1	INJURIES TO WILLBROS GROUP PERSONNEL AND DAMAGE TO
WILLBROS GROUP PROPERTY: WILLBROS HEREBY RELEASES, AND AGREES TO DEFEND,
INDEMNIFY, AND HOLD THE CHENIERE GROUP HARMLESS FROM AND AGAINST, ANY
AND ALL CLAIMS, DEMANDS, CAUSES OF ACTION, SUITS, LIABILITIES, LOSSES, DAMAGES
AND EXPENSES INCLUDING COURT COSTS AND REASONABLE ATTORNEY’S FEES
(COLLECTIVELY, “CLAIMS”) ARISING OUT OF OR RESULTING FROM (1) INJURY TO
OR DEATH OF THE WILLBROS GROUP PERSONNEL, OR (2) DAMAGE TO OR
DESTRUCTION OF THE WILLBROS GROUP PROPERTY, WHETHER OR NOT SUCH CLAIMS
ARE DUE TO AN ACT, OMISSION, NEGLIGENCE WHETHER CONTRIBUTORY, JOINT, OR
SOLE, FAULT OR STRICT LIABILITY OF THE CHENIERE GROUP, BUT EXCLUDING
ONLY THOSE CLAIMS DUE TO THE WILLFUL MISCONDUCT OF THE CHENIERE
GROUP. 

  

	 	10.1.2	 THIRD PARTY INDEMNIFICATION: WILLBROS HEREBY
RELEASES, AND AGREES TO DEFEND, INDEMNIFY, AND HOLD CHENIERE GROUP HARMLESS
FROM AND AGAINST, ANY AND ALL CLAIMS ARISING OUT OF OR RESULTING
FROM DAMAGE TO OR DESTRUCTION OF PROPERTY OR PERSONAL INJURY TO OR
DEATH OF ANY THIRD PARTY (OTHER THAN A MEMBER OF THE CHENIERE
GROUP OR THE WILLBROS 

  

 A-26 

	 	 
GROUP) TO THE EXTENT ARISING OUT OF
OR RESULTING FROM WILLBROS’ OR ITS SUBCONTRACTORS’ OR VENDORS’ PERFORMANCE
OF THE WORK, INCLUDING THE BREACH OF THIS AGREEMENT BY WILLBROS AND
THE NEGLIGENCE, GROSS NEGLIGENCE OR WILLFUL MISCONDUCT OF WILLBROS, ITS
SUBCONTRACTORS, ITS VENDORS OR ANYONE EMPLOYED BY THEM OR ANYONE FOR
WHOSE ACTS THEY MAY BE LIABLE. 

  

	 	10.1.3	INJURIES TO CHENIERE GROUP PERSONNEL AND DAMAGE TO
CHENIERE GROUP PROPERTY: CHENIERE HEREBY RELEASES, AND AGREES TO DEFEND,
INDEMNIFY, AND HOLD THE WILLBROS GROUP HARMLESS FROM AND AGAINST, ANY
AND ALL CLAIMS ARISING OUT OF OR RESULTING FROM (1) INJURY TO OR
DEATH OF THE CHENIERE GROUP PERSONNEL, OR (2) DAMAGE TO OR DESTRUCTION
OF THE CHENIERE GROUP PROPERTY (EXCLUDING THE WORK OR THE PROJECT),
WHETHER OR NOT SUCH CLAIMS ARE DUE TO AN ACT, OMISSION, NEGLIGENCE
WHETHER CONTRIBUTORY, JOINT, OR SOLE, FAULT OR STRICT LIABILITY OF THE
WILLBROS GROUP, BUT EXCLUDING ONLY THOSE CLAIMS DUE TO THE WILLFUL
MISCONDUCT OF THE WILLBROS GROUP. 

  

	 	10.1.4	HAZARDOUS SUBSTANCES INDEMNIFICATION: WILLBROS HEREBY RELEASES,
AND AGREES TO DEFEND, INDEMNIFY AND HOLD CHENIERE GROUP HARMLESS FROM
ANY AND ALL CLAIMS, FINES, PENALTIES OR REMEDIATION OBLIGATIONS ARISING OUT
OF OR RESULTING FROM (A) ACTUAL OR ALLEGED POLLUTION OR CONTAMINATION
OF THE LAND, WATER OR AIR ARISING FROM SPILLS, RELEASES, DISCHARGES
OR OTHERWISE OF HAZARDOUS SUBSTANCES, INCLUDING FUELS, LUBRICANTS, MOTOR OILS, PIPE
DOPE, PAINTS, SOLVENTS, AND GARBAGE, USED, HANDLED OR DISPOSED OF BY
WILLBROS OR ITS SUBCONTRACTORS OR VENDORS DURING THE PERFORMANCE OF THE
WORK, AND (B) ANY ENVIRONMENTAL DAMAGE OF ANY OTHER NATURE TO
THE EXTENT RESULTING FROM THE PERFORMANCE OF THE WORK BY WILLBROS OR
ITS SUBCONTRACTORS OR VENDORS; PROVIDED, HOWEVER, THAT WILLBROS SHALL HAVE NO
LIABILITY OR RESPONSIBILITY FOR ANY POLLUTION, CONTAMINATION OR ENVIRONMENTAL DAMAGE
EXISTING AT THE WORK SITE PRIOR TO THE COMMENCEMENT OF THE WORK.

  

	 	10.1.5	COMPLIANCE WITH APPLICABLE LAW INDEMNIFICATION: WILLBROS
HEREBY RELEASES, AND AGREES TO DEFEND, INDEMNIFY AND HOLD CHENIERE GROUP
HARMLESS FROM ANY AND ALL CLAIMS, FINES, PENALTIES OR REMEDIATION OBLIGATIONS
TO THE EXTENT ARISING OUT OF OR RESULTING FROM WILLBROS’ OR ITS
SUBCONTRACTORS’ OR VENDORS’ ACTUAL OR ALLEGED FAILURE TO COMPLY WITH
APPLICABLE LAW OR APPLICABLE CODES AND STANDARDS, OR ANY JUDICIAL ARBITRAL
OR REGULATORY INTERPRETATION THEREOF. 

  

	 	10.1.6	 WAIVER OF CONSEQUENTIAL DAMAGES: NOTWITHSTANDING ANY
OTHER PROVISIONS IN THIS AGREEMENT TO THE CONTRARY, IN NO EVENT SHALL
ANY ENTITY IN EITHER CHENIERE GROUP OR THE WILLBROS GROUP BE LIABLE,
ONE TO THE OTHER, FOR INDIRECT, SPECIAL, INCIDENTAL OR CONSEQUENTIAL DAMAGES,

  

 A-27 

	 	 
INCLUDING LOSS OF PROFITS, LOSS OF USE
OF ASSETS, OR BUSINESS INTERRUPTION UNDER THIS AGREEMENT OR ANY CAUSE
OF ACTION RELATED THERETO, PROVIDED THAT THE LIMITATION OF LIABILITY SET
FORTH IN THIS PARAGRAPH 10.1.6 SHALL NOT APPLY TO (A) WILLBROS’
CONFIDENTIALITY OBLIGATIONS AS PROVIDED BY THIS AGREEMENT; (B) WILLBROS’ INDEMNIFICATION
OBLIGATIONS FOR THIRD PARTY CLAIMS UNDER THIS AGREEMENT; (C) THE AMOUNTS
ENCOMPASSED WITHIN THE LIQUIDATED DAMAGES PROVIDED FOR IN PARAGRAPH 21; OR
(D) AS EXPRESSLY PERMITTED UNDER PARAGRAPH 21.2. 

  

	10.2	LIEN INDEMNIFICATION: WITHOUT IN ANY WAY LIMITING
THE FOREGOING, SO LONG AS CHENIERE REMITS UNDISPUTED PAYMENTS TO WILLBROS
WHEN DUE UNDER THIS AGREEMENT, WILLBROS HEREBY RELEASES, AND AGREES TO
DEFEND, INDEMNIFY AND HOLD CHENIERE GROUP HARMLESS FROM, AND SHALL KEEP
THE WORK, THE WORK SITE AND THE PROJECT FREE AND CLEAR OF,
ANY AND ALL LIENS AND ENCUMBRANCES ASSERTED BY AN ENTITY ACTING
THROUGH WILLBROS, ANY SUBCONTRACTOR, ANY VENDOR OR ANY OTHER PERSON OR
ENTITY ACTING THROUGH OR UNDER ANY OF THEM. IF WILLBROS FAILS TO
DISCHARGE SUCH LIEN OR ENCUMBRANCE OR POST ADEQUATE SECURITY WITH RESPECT
THERETO WITHIN THIRTY (30) DAYS OF THE FILING OF SUCH LIEN OR
ENCUMBRANCE, CHENIERE, IF IT SO ELECTS, MAY DISCHARGE ANY SUCH LIENS
OR ENCUMBRANCES, AND WILLBROS SHALL BE LIABLE TO CHENIERE FOR ALL
DAMAGES, COSTS, LOSSES, AND EXPENSES (INCLUDING ALL ATTORNEYS’ FEES, CONSULTANT
FEES AND LITIGATION OR ARBITRATION EXPENSES) INCURRED BY CHENIERE ARISING OUT
OF OR RELATING TO SUCH DISCHARGE OR RELEASE. THEREAFTER, CHENIERE MAY
INVOICE WILLBROS FOR SUCH AMOUNT OWED (WHICH INVOICE SHALL BE PAID BY
WILLBROS WITHIN THIRTY (30) DAYS AFTER RECEIPT THEREOF) OR DEDUCT THE AMOUNT
SO PAID BY CHENIERE FROM SUMS DUE OR WHICH THEREAFTER BECOME DUE
TO WILLBROS HEREUNDER. 

  

	10.3	 PATENT AND COPYRIGHT INDEMNIFICATION: WILLBROS
HEREBY RELEASES, AND AGREES TO DEFEND, INDEMNIFY AND HOLD CHENIERE GROUP
HARMLESS FROM ANY CLAIMS TO THE EXTENT ARISING FROM OR RELATING TO
THE ACTUAL OR ALLEGED INFRINGEMENT OF ANY DOMESTIC OR FOREIGN PATENTS,
COPYRIGHTS, TRADEMARKS OR OTHER INTELLECTUAL PROPERTY RIGHTS THAT MAY BE
ATTRIBUTABLE TO WILLBROS OR ITS SUBCONTRACTORS OR VENDORS IN CONNECTION WITH
THE WORK. IN THE EVENT THAT ANY SUIT, CLAIM, TEMPORARY RESTRAINING
ORDER OR PRELIMINARY INJUNCTION IS GRANTED IN CONNECTION WITH THIS PARAGRAPH 10.3,
WILLBROS SHALL, IN ADDITION TO ITS OBLIGATION ABOVE, MAKE EVERY REASONABLE
EFFORT, BY GIVING A SATISFACTORY BOND OR OTHERWISE, TO SECURE THE
SUSPENSION OF THE INJUNCTION OR RESTRAINING ORDER. IF, IN ANY SUCH
SUIT OR CLAIM, THE WORK, THE PROJECT OR ANY PART, COMBINATION OR
PROCESS THEREOF, IS HELD TO CONSTITUTE AN INFRINGEMENT AND ITS USE IS
PRELIMINARILY OR PERMANENTLY ENJOINED, WILLBROS SHALL PROMPTLY MAKE EVERY REASONABLE
EFFORT TO SECURE FOR CHENIERE A LICENSE, AT NO COST TO CHENIERE,
AUTHORIZING CONTINUED USE OF THE INFRINGING WORK. IF WILLBROS IS UNABLE
TO SECURE SUCH A LICENSE WITHIN A REASONABLE TIME, WILLBROS SHALL, AT
ITS OWN EXPENSE AND WITHOUT IMPAIRING PERFORMANCE REQUIREMENTS, EITHER REPLACE THE

  

 A-28 

	 	 
AFFECTED WORK, IN WHOLE OR PART, WITH
NON-INFRINGING COMPONENTS OR PARTS OR MODIFY THE SAME SO THAT THEY
BECOME NON-INFRINGING. 

  

	10.4	ATTORNEYS’ FEES: EACH PARTY AGREES TO REIMBURSE
THE PREVAILING PARTY FOR ANY AND ALL NECESSARY EXPENSES, ATTORNEY’S
FEES, AND RELATED COSTS INCURRED IN THE ENFORCEMENT OF ANY PART OF
THE INDEMNITY AGREEMENTS PROVIDED FOR HEREIN. 

  

	10.5	Enforceability: 

  

	 	10.5.1	Exclusions to Liability and Indemnity: Except as expressly provided elsewhere in this Agreement, the exclusions of liability and indemnities herein shall apply according to
their terms to any such Claim, loss, damage, expense, injury, illness or death, without regard to the cause thereof, including strict liability, ultra hazardous activity, breach of express or implied warranty, imperfection of material, defect or
failure of equipment, defect or “ruin” or other condition of premises, or the sole or concurrent negligence or other fault of the party being indemnified. 

  

	 	10.5.2	CONCURRENT NEGLIGENCE: EXCEPT AS OTHERWISE SET FORTH
IN PARAGRAPHS 10.1.1 AND 10.1.3, THE INDEMNITY, DEFENSE AND HOLD HARMLESS OBLIGATIONS
FOR PERSONAL INJURY OR DEATH OR PROPERTY DAMAGE UNDER THIS AGREEMENT
SHALL APPLY REGARDLESS OF WHETHER THE INDEMNIFIED PARTY WAS CONCURRENTLY NEGLIGENT
(WHETHER ACTIVELY OR PASSIVELY), IT BEING AGREED BY THE PARTIES THAT
IN THIS EVENT, THE PARTIES’ RESPECTIVE LIABILITY OR RESPONSIBILITY FOR SUCH
DAMAGES, LOSSES, COSTS AND EXPENSES UNDER THIS PARAGRAPH 10 SHALL BE DETERMINED
IN ACCORDANCE WITH PRINCIPLES OF COMPARATIVE NEGLIGENCE. 

  

	 	10.5.3	Louisiana Oilfield Anti-Indemnity Act: Willbros and Cheniere agree that the Louisiana Oilfield Anti-Indemnity Act, LA. REV. STAT.
§ 9:2780, ET. SEQ., is inapplicable to this Agreement and the performance of the Work. Application of these code sections to this Agreement would be contrary to the intent of the Parties, and each Party hereby
irrevocably waives any contention that these code sections are applicable to this Agreement or the Work. In addition, it is the intent of the Parties in the event that the aforementioned act were to apply that each Party shall provide insurance to
cover the losses contemplated by such code sections and assumed by each such Party under the indemnification provisions of this Agreement, and Willbros agrees that the payments made to Willbros hereunder compensate Willbros for the cost of premiums
for the insurance provided by it under this Agreement. The Parties agree that each Party’s agreement to support their indemnification obligations by insurance shall in no respect impair their indemnification obligations.

  

	 	10.5.4	 Conflict with Applicable Law: In the event that any indemnity provisions in this Agreement are contrary to the law governing this Agreement, then the
indemnity 

  

 A-29 

	 	 
obligations applicable hereunder shall be applied to the maximum extent allowed by Applicable Law. 

 11. INSURANCE 
  

	11.1	Willbros’ Insurance: All insurance obtained pursuant to this Agreement shall: (1) be issued by insurers with an “A-X” or better A.M. Best Co. rating in
the current Property-Casualty Edition and authorized to do business in the state in which the Project is located, and (2) be in all other respects acceptable to Cheniere. Willbros shall carry and maintain or cause to be carried and maintained
in force at all times during the term of the Agreement the following insurance: 

  

	 	11.1.1	Workers’ Compensation/Employers’ Liability 

 Workers’ compensation with appropriate longshoremen’s or harbor workers’ endorsement (if applicable) covering all Willbros Personnel in accordance with the statutory requirements of the state of hire or country in which the
Work is to be performed, and if the Work includes the use of vessels, appropriate maritime extensions. Employers’ liability insurance with the limit of One Million United States Dollars (U.S. $l,000,000) per accident or illness. 
  

	 	11.1.2	Commercial General Liability 

 Commercial general
liability insurance with contractual liability, products and completed operations, and broad form property damage coverage included, which shall provide for a combined single limit of One Million United States Dollars (U.S. $1,000,000) for personal
injury, death or property damage resulting from each occurrence and covering all of Willbros’ Work under the Agreement; provided, however, this coverage requirement may be satisfied by Willbros through any combination of primary and excess
liability insurance. 
  

	 	11.1.3	Automobile Liability 

 Automobile liability
insurance covering owned, non-owned and hired motor vehicles, with combined single limits of at least One Million United States Dollars (U.S. $1,000,000) for personal injury, death, or property damage resulting from each occurrence. 
  

	 	11.1.4	Aircraft Liability Insurance 

 Aircraft liability
insurance, to the extent applicable, covering owned, non-owned and hired aircraft with a combined single limit of Five Million United States Dollars (U.S. $5,000,000) for bodily injury, death and property damage resulting from each occurrence.

  

 A-30 

	 	11.1.5	Transportation Insurance 

 “All Risk”
Insurance covering the full replacement cost of all supplies, equipment and materials to be incorporated into the Work while in the course of transit, including the land portion of any ocean or air shipments, and until arrival at the final local
Work Sites. Such transit insurance shall include coverage against the perils of war, strikes, riots and civil commotion and shall insure all general average and salvage charges for which named insureds are responsible. Such insurance shall have a
deductible of Fifty Thousand United States Dollars (U.S. $50,000) per loss. 
  

	 	11.1.6	Builder’s Risk Insurance 

 Completed value
form builder’s risk property insurance (subject to a deductible per loss not to exceed $50,000) upon the entire Work for one hundred percent (100%) of the full replacement cost value thereof (100% includes additional costs of engineering
services in the event of a loss). This policy shall include the interests of Cheniere Group and Willbros Group in the Work as named insureds, as their interests may appear, shall name Cheniere as the loss payee, and shall be on an “All
Risk” basis for physical loss or damage including fire, flood, earthquake, subsidence, hail, theft, vandalism and malicious mischief and shall include coverage for portions of the Work while it is stored off the Work Site or is in transit
(except as otherwise covered by Paragraph 11.1.5). This policy shall provide, by endorsement or otherwise, that Willbros shall be solely responsible for the payment of all premiums under the policy, and that the Cheniere Group shall have no
obligation for the payment thereof, notwithstanding that the Cheniere Group are named insureds under the policy. Willbros shall be responsible for any loss within the deductible of the policy for the liabilities assumed by Willbros hereunder.

  

 A-31 

	 	11.1.7	Errors and Omissions Insurance 

 Errors and
Omissions Professional Liability Insurance (“E&O Insurance”) having minimum limits of Five Million United States Dollars (U.S.$5,000,000) per claim and in the aggregate, with a deductible not in excess of Two Hundred Fifty Thousand
United States Dollars (U.S.$250,000) per claim and in the aggregate, on a claims made basis. E&O Insurance shall cover liability arising out of or based upon any negligent design, engineering or other professional services performed by Willbros
or any of its Subcontractors which is required as or associated with any part of the Work. The E&O Insurance shall have a retroactive date prior to the performance of any Work to be provided under this Agreement, shall have a policy period or
renewal period extending through the termination or expiration of this Agreement and for two (2) years thereafter, and shall state that in the event of cancellation or non-renewal, the discovery period for insurance claims (tail coverage) shall
be at least thirty-six (36) months. 
  

	 	11.1.8	Excess Liability Insurance 

 Umbrella or excess
liability insurance, written on a “following form” basis and providing coverage in excess of the coverages required to be provided by Willbros for employer’s liability insurance, commercial general liability insurance and automobile
liability insurance, with limits of Twenty-Five Million United States Dollars (U.S.$25,000,000) combined single limit each claim and in the aggregate. 
  

	11.2	Notice: Willbros shall have the insurance carriers furnish to Cheniere, upon the Effective Date and annually thereafter, insurance certificates specifying the types and
amounts of coverage in effect and the expiration dates of each policy, and a statement that no insurance will be canceled or materially changed without thirty (30) days prior written notice to Cheniere. 

  

	11.3	Waiver of Subrogation: All policies of insurance required to be provided by Willbros under this Agreement shall include clauses providing that each underwriter shall waive
its rights of recovery, under subrogation or otherwise, against the Cheniere Group for the liabilities assumed by Willbros hereunder. Insurance policies pursuant to Paragraphs 11.1.2, 11.1.3, 11.1.4, 11.1.5, 11.1.6 and 11.1.8 shall designate
Cheniere as additional insured for the liabilities assumed by Willbros hereunder, and that the policies provided by Willbros shall be primary and noncontributing to any insurance carried by Cheniere with regard to the liabilities assumed by Willbros
hereunder. The policies referred to in Paragraphs 11.1.2 and 11.1.3 shall contain a cross-liability clause in respect of third party claims so that Cheniere and Willbros are regarded as third parties as to each other. 

  

	11.4	 Obligations Not Relieved: Except as otherwise provided in this Agreement to the contrary, the occurrence of any of the following shall in no way relieve
Willbros from any of its obligations under this Agreement: (i) failure by Willbros to secure or maintain the insurance coverage required hereunder; (ii) failure by Willbros to comply fully with any 

  

 A-32 

	 	 
of the insurance provisions of this Agreement; (iii) failure by Willbros to secure such endorsements on the policies as may be necessary to carry out
the terms and provisions of this Agreement; (iv) the insolvency, bankruptcy or failure of any insurance company providing insurance to Willbros; (v) failure of any insurance company to pay any claim accruing under its policy; or
(vi) losses by Willbros or any of its Subcontractors or Vendors not covered by insurance policies. 

  

	11.5	Subcontractors’ and Vendors’ Insurance: If Willbros subcontracts any part of the Work, Willbros shall obtain or require its Subcontractors and Vendors to maintain,
the same insurance coverage and amounts that Willbros is required to maintain pursuant to this Paragraph 11, as applicable and appropriate to the Work of such Subcontractor or Vendor. 

  

	11.6	Parent Guarantee: Willbros will guarantee the full and faithful performance of all obligations of Willbros under this Agreement by providing Cheniere with a parent guarantee
in the form attached as Attachment I. 

  

	11.7	Performance and Payment Bonds: Prior to commencement of the construction component of the Work and in any event no later than thirty (30) days prior to Cheniere’s
payment to Willbros of the down payment for such Work in accordance with Paragraph 1.4.1(i) of Attachment I to the Letter Agreement, Willbros shall cause the construction Subcontractor to provide to Cheniere and maintain performance and
payment bonds in the form of Attachment II and in an amount equal to the amount of the cost of construction, as indicated in the Schedule of Values. Such bonds shall be provided by a surety licensed to transact business in the State of
Louisiana, U.S. Department of Treasury listed and otherwise approved by Cheniere, which approval shall not be unreasonably withheld. Each bond shall also attach the respective dual obligee riders set forth in Attachment II, naming
Cheniere as a dual obligee under each bond. The premium of such bonds shall be reimbursed to Willbros by Cheniere and shall be included in the Guaranteed Maximum Price. 

  

	11.8	 Limitation of Liability. Notwithstanding any other provision of this Agreement, under no circumstance shall the liability of Willbros to Cheniere in
connection with the Work exceed in the cumulative aggregate fifteen percent (15%) of the cost of construction, as indicated in the Schedule of Values and as may be adjusted by Change Order, provided that, notwithstanding the foregoing, the
limitation of liability set forth in this Paragraph 11.8 shall not (i) apply in the event of Willbros’ willful misconduct (including the willful refusal to perform the Work, willful delay in performing the Work or abandonment of the Work)
or gross negligence; (ii) apply to Willbros’ indemnification obligations under this Agreement; or (iii) include the payment of proceeds under any insurance policy required to be provided by Willbros under Paragraph 11.1, Cheniere or
any Subcontractor or Vendor. In no event shall the limitation of liability set forth in this Paragraph 11.8 be in any way deemed to limit Willbros’ obligation to perform all Work required to achieve Mechanical Completion, Start-up and Project
Completion. The costs incurred by Willbros in performing the Work (including Corrective Work and other Warranty 

  

 A-33 

	 	 
obligations but excluding the payment of Liquidated Damages) shall not be counted against the aggregate limitation of liability set forth in this Paragraph
11.8. 

 12. WARRANTY 
  

	12.1	General: Any Work, or component thereof, that is not in conformity with any warranties set forth in this Paragraph 12 and elsewhere in this Agreement (collectively, the
“Warranty” or “Warranties”) is defective (“Defective”) and contains a defect (“Defect”). Willbros hereby warrants that the Work and each component thereof shall be: 

  

	 	12.1.1	new, complete, fit for the purposes specified in this Agreement and of suitable grade for the intended function and use; 

  

	 	12.1.2	in accordance with all of the requirements of this Agreement, including in accordance with good engineering and construction practices, Applicable Law and Applicable Codes and
Standards; 

  

	 	12.1.3	free from encumbrances to title, as set forth in greater detail in Paragraph 10.2; and 

  

	 	12.1.4	free from defects in design, material and workmanship and otherwise conform to the standards and requirements contained in the Specifications and elsewhere in this Agreement.

 Willbros and its Subcontractors and Vendors shall exercise that high degree of skill and judgment normally exercised by firms
performing services of a similar nature. 
  

	12.2	Correction of Work: 

  

	 	12.2.1	Prior to Start-up: Willbros’ obligations to correct Work prior to Start-up are set forth in Paragraph 7.4. 

  

	 	12.2.2	 After Start-up: If within twelve (12) months after Start-up (the “Defect Correction Period”) any Work is found to be Defective, Willbros
shall, at its sole cost and expense, immediately and on an expedited basis correct such Defective Work and any other portions of the Project damaged or affected by such Defective Work, whether by repair, replacement or otherwise (“Corrective
Work”) and shall be liable for and pay to Cheniere any and all costs, losses, damages and expenses incurred by Cheniere arising out of or relating to such Defective Work. Cheniere shall provide Willbros with access to the Project sufficient to
perform its Corrective Work, so long as such access does not unreasonably interfere with operation of the Project and subject to any reasonable security or safety requirements of Cheniere. In the event Willbros utilizes spare parts owned by Cheniere
in the course of performing the Corrective Work, Willbros shall supply Cheniere free of charge with new spare parts equivalent in quality and quantity to 

  

 A-34 

	 	 
all such spare parts used by Willbros as soon as possible following the utilization of such spare parts. 

  

	 	12.2.3	Cheniere’s Right to Correct or Complete Defective Work: If Willbros fails to commence the Corrective Work within a reasonable period of time not to exceed forty-eight
(48) hours, or does not complete such Corrective Work on an expedited basis, then Cheniere, by written notice to Willbros, may (without prejudice to any other remedies that it may have under this Agreement) correct such Defective Work, and
Willbros shall be liable to Cheniere for all costs, losses, damages and expenses incurred by Cheniere in connection with correcting such Defective Work and arising out of or relating to such Defective Work and shall pay Cheniere (directly, or by
offset, at Cheniere’s sole discretion) an amount equal to such costs, losses, damages and expenses; provided, however, if such Defective Work presents an imminent threat to the safety or health of any person and Cheniere knows of such Defective
Work, Cheniere may (without prejudice to any other remedies that it has under this Agreement) correct such Defective Work without giving prior written notice to Willbros, and, in that event, Willbros shall be liable to Cheniere for all reasonable
costs, losses, damages and expenses incurred by Cheniere in connection with correcting such Defective Work and arising out of or relating to such Defective Work and shall pay Cheniere (directly or by offset, at Cheniere’s sole discretion) an
amount equal to such costs, losses, damages and expenses. 

  

	 	12.2.4	Extended Defect Correction Period for Corrective Work: With respect to any Corrective Work performed, the Defect Correction Period for such Corrective Work shall be extended
for an additional twelve (12) months from the date of the completion of such Corrective Work; provided, however, in no event shall the Defect Correction Period for such Corrective Work be less than the original Defect Correction Period. In no
event shall the Defect Correction Period plus any extended Defect Correction Period exceed a total period of twenty-four (24) months. 

  

	 	12.2.5	Standards for Corrective Work: All Corrective Work shall be performed subject to the same terms and conditions under this Agreement as the original Work is required to be
performed. 

  

	 	12.2.6	 No Limitation: Nothing contained in this Paragraph 12.2 shall be construed to establish a period of limitation with respect to other obligations which
Willbros might have under the Agreement. Establishment of the Defect Correction Period relates only to the specific obligation of Willbros to perform Corrective Work, and has no relationship to the time within which the obligation to comply with
this Agreement may be sought to be enforced, nor to the time within which proceedings may be commenced to establish Willbros’ liability with respect to Willbros’ obligations other than specifically to perform Corrective Work. In addition,
all representations, Warranties and obligations to perform Corrective 

  

 A-35 

	 	 
Work set forth in this Agreement, including those in this Paragraph 12, shall be in addition to and shall in no way limit Willbros’ obligation to
perform all Work necessary to achieve Project Completion. 

  

	 	12.2.7	Vendor Correction of Work Warranties for Materials or Equipment: Notwithstanding anything to the contrary in this Agreement, with respect to any materials or equipment
procured by Willbros from a Vendor, Willbros’ liability during the Defect Correction Period for such materials and equipment shall be limited to “passing through” to Cheniere the benefits of any correction of Work warranty received
from the applicable Vendor, which correction of Work obligation shall be deemed to run to the benefit of Cheniere. Willbros shall use its best efforts to obtain a correction of Work warranty identical to Willbros’ correction of Work obligations
set forth in Paragraph 12.2.2, but in no event shall such correction of Work obligations be less than industry standard and otherwise reasonable to protect Cheniere from Defective Work. Willbros shall use its best efforts to cause such Vendors to
perform their obligations under such warranties, and shall cooperate with Cheniere’s efforts to enforce such warranties with any such Vendors. Willbros shall assign in full, and without cost to Cheniere, all such warranties from such Vendors.
In the event of a Dispute during the Defect Correction Period as to whether Defective Work relates to a Defect in workmanship (and, therefore, is covered by Paragraph 12.2.2) or a Defect in material or equipment provided by a Vendor (and, therefore,
is covered by this Paragraph 12.2.7), anything in this Paragraph notwithstanding, Willbros shall, at Cheniere’s direction and subject to the dispute resolution procedure set forth in Article 14, perform Corrective Work during the Defect
Correction Period unless Willbros successfully causes such Vendor to perform its correction of Work obligations in accordance with the terms of the applicable purchase order. 

  

	12.3	 Assignment and Enforcement of Subcontractor Warranties: Willbros shall, without additional cost to Cheniere, obtain Warranties from Subcontractors that meet
or exceed the requirements of this Agreement; provided, however, Willbros shall not in any way be relieved of its responsibilities and liability to Cheniere under this Agreement, regardless of whether such Subcontractor Warranties meet the
requirements of this Agreement, as Willbros shall be fully responsible and liable to Cheniere for its Warranty and corrective Work obligations and liability under this Agreement for all Work. All such Warranties shall be deemed to run to the benefit
of Cheniere and Willbros. Such Warranties, with duly executed instruments assigning the Warranties to Cheniere, shall be delivered to Cheniere upon Start-up. All Warranties provided by any Subcontractor shall be in such form as to permit direct
enforcement by Willbros or Cheniere against any Subcontractor whose Warranty is called for, and Willbros agrees that: (i) Willbros’ Warranty, as provided under this Paragraph 12 shall apply to all Work regardless of the provisions of any
Subcontractor Warranty, and such Subcontractor Warranties shall be in addition to, and not a limitation of, such Willbros Warranty; (ii) Willbros is jointly and severally liable with such Subcontractor with respect to such Subcontractor
Warranty; and (iii)

  

 A-36 

	 	 
service of notice on Willbros that there has been a breach of a Subcontractor Warranty shall be sufficient to invoke the terms of the instrument.

  

	12.4	Survival of Warranties: All representations and Warranties set forth in this Agreement, including those in this Paragraph 12, shall survive Project Completion or the earlier
termination of this Agreement. 

 13. TITLE TO THE WORK AND TO WORK PRODUCT, 
 CONFIDENTIAL INFORMATION 
  

	13.1	Title: The title to all or any portion of the Work (other than Work Product) shall pass to Cheniere upon the earlier of (a) payment by Cheniere therefore, or
(b) incorporation of such Work into the Work Site. Notwithstanding the foregoing, title to all materials furnished by Cheniere, irrespective of the location thereof, as between Cheniere and Willbros or any Subcontractor or Vendor, shall be in
Cheniere. Transfer of title to Work shall be irrespective of the passage of risk of loss pursuant to Paragraph 13.2 and shall be without prejudice to Cheniere’s right to reject Defective Work or any other right in this Agreement.

  

	13.2	Risk of Loss: Notwithstanding passage of title pursuant to Paragraph 13.1, Willbros shall bear the risk of loss and damage to Work until the earlier of Start-up or
termination of this Agreement; provided that Cheniere shall at all times bear the risk of physical loss and damage if and to the extent arising from (i) war (whether declared or undeclared), civil war, act of terrorism, sabotage, blockade,
insurrection; or (ii) ionizing radiation, or contamination by radioactivity from nuclear fuel, or from any nuclear waste from the combustion of nuclear fuel properties of any explosive nuclear assembly or nuclear component thereof. In the event
that any physical loss or damage to the Work arises from one or more of the events set forth in the preceding sentence, and Cheniere elects to rebuild such physical loss or damage, Willbros shall be entitled to a Change Order to the extent such
event adversely affects (i) Willbros’ costs of performance of the Work; (ii) Willbros’ ability to perform the Work in accordance with the Work Plan or (iii) Willbros’ ability to perform any material obligation under
this Agreement; provided that Willbros complies with the requirements set forth in Paragraphs 9.5 and 14.1. 

  

	13.3	 Ownership of Work Product: Subject to Paragraph 13.4, all materials which Willbros or any Subcontractor or Vendor is required to furnish, prepare or develop
in the performance and completion of Work hereunder (whether delivered to Cheniere or not), including reports, plans, Drawings and Specifications, calculations, maps, sketches, notes, data and samples (collectively, “Work Product”), shall
be “works for hire,” and all rights, title and interests to the Work Product, including any and all copyrights in the Work Product, shall be the sole and exclusive property of Cheniere without limitation (except Willbros may retain a copy
thereof in accordance with this Agreement), subject only to Willbros’ right to use the same to perform the Work. Such Work Product (including all copies thereof) shall, together with any materials furnished by Cheniere hereunder, be delivered
to Cheniere upon request and in any event upon completion or termination of this 

  

 A-37 

	 	 
Agreement. All such Work Product shall be considered to be Cheniere’s Confidential Information and is subject to the confidentiality obligations in
Paragraph 13.6. If for any reason any part of or all of the Work Product is not considered work for hire for Cheniere or if ownership of all right, title and interest in the Work Product shall not otherwise vest in Cheniere, then Willbros agrees
that such ownership and copyrights in the Work Product, whether or not such Work Product is fully or partially complete, shall be automatically assigned from Willbros to Cheniere, without further consideration, and Cheniere shall thereafter own all
right, title and interest in the Work Product, including all copyright interests. 

  

	13.4	Willbros Intellectual Property: As between Cheniere and Willbros, Willbros shall retain ownership of any intellectual property rights owned by Willbros or developed by
Willbros outside this Agreement and prior to the Effective Date (“Willbros’ Intellectual Property”). To the extent any Willbros’ Intellectual Property is incorporated, in whole or in part, into the Work Product, Willbros shall
provide prior written notice thereof to Cheniere. Cheniere shall be entitled to use Willbros’ Intellectual Property and Willbros hereby grants Cheniere an irrevocable and royalty-free license to use and modify Willbros’ Intellectual
Property for the sole purposes of: (i) operating and maintaining the Project; (ii) assisting in the performance of the Work; or (iii) repairing, replacing, expanding, completing or modifying any portion of the Work or the Project.
Cheniere shall be entitled to assign its rights in such license, provided that such assignee shall only use such license for the purposes specified in (i) through (iii) above. 

  

	13.5	Cheniere’s Use of the Work Product and Willbros’ Intellectual Property for Other Projects: In addition to the license granted in Paragraph 13.4, Cheniere shall be
entitled to use the Work Product and Willbros hereby grants solely to Cheniere an irrevocable and royalty-free license, non-transferable and non-assignable (except as set forth below) to use Willbros’ Intellectual Property embedded in the Work
Product, in each case solely for the purpose of developing other projects owned in whole or part by Cheniere, including the Corpus Christi and Creole Trail projects, provided that (i) Cheniere shall first remove all references to Willbros and
the Project from the Work Product and Willbros’ Intellectual Property embedded in the Work Product, (ii) the use of any of Willbros’ Intellectual Property on such other projects shall be limited to such Willbros’ Intellectual
Property which is embedded in the Work Product; and (iii) Cheniere shall not assign (except to an affiliated company of Cheniere) such Work Product or license without Willbros’ consent, which consent shall not be unreasonably withheld or
delayed. CHENIERE SHALL DEFEND, INDEMNIFY AND HOLD WILLBROS HARMLESS FROM AND AGAINST ALL DAMAGES, LOSSES, COSTS AND EXPENSES (INCLUDING ALL REASONABLE ATTORNEYS’ FEES AND LITIGATION OR ARBITRATION EXPENSES) INCURRED BY WILLBROS AND CAUSED BY
USE OF THE WORK PRODUCT OR WILLBROS’ INTELLECTUAL PROPERTY IN CONNECTION WITH PROJECTS OTHER THAN THE PROJECT WHICH IS THE SUBJECT OF THIS AGREEMENT. 

  

 A-38 

	13.6	Willbros’ Confidentiality Obligations: Willbros hereby covenants and warrants that Willbros and its employees and agents shall not (without in each instance obtaining
Cheniere’s prior written consent) disclose, make commercial or other use of, or give or sell to any person or entity any of the following information: (i) any Work Product other than to Subcontractors or Vendors as necessary to perform the
Work or (ii) any other information relating to the business, products, services, research or development, clients or customers of Cheniere or any member of the Cheniere Group, or relating to similar information of a third party who has
entrusted such information to Cheniere or any member of the Cheniere Group (hereinafter individually or collectively, “Cheniere’s Confidential Information”). Prior to disclosing any information in (i) of this Paragraph 13.6 to
any Subcontractor or Vendor as necessary to perform the Work, Willbros shall bind such Subcontractor or Vendor to the confidentiality obligations contained in this Paragraph 13.6 and to the term in Paragraph 13.11. Nothing in this Paragraph 13.6 or
this Agreement shall in any way prohibit Willbros or any of its Subcontractors or Vendors from making commercial or other use of, selling, or disclosing any of their respective Willbros’ Intellectual Property. 

  

	13.7	Cheniere’s Confidentiality Obligations: Cheniere hereby covenants and warrants that Cheniere and its employees and agents shall not (without in each instance obtaining
Willbros’ prior written consent) disclose, make commercial or other use of, or give or sell to any person or entity any pricing methodologies or pricing information (other than the Guaranteed Maximum Price or actual expenditures made by
Willbros under this Agreement) relating to the Work, which is conspicuously marked and identified in writing as confidential by Willbros (hereinafter individually or collectively, “Willbros’ Confidential Information”). The Parties
agree that Cheniere may disclose Willbros’ Confidential Information to any member of the Cheniere Group, underwriters, a bona fide prospective purchaser of all or a portion of Cheniere’s or any member of the Cheniere Group’s assets or
ownership interests, a bona fide prospective assignee of all or a portion of Cheniere’s interest in this Agreement, lender and its representatives, rating agencies or any other party in relation to project financing for the Project, provided
that Cheniere binds such persons or entity to the confidentiality obligations contained in this Paragraph 13.7 and to the term in Paragraph 13.11. 

  

	13.8	Definitions: The term “Confidential Information” shall mean one or both of Willbros’ Confidential Information and Cheniere’s Confidential Information, as
the context requires. The Party having the confidentiality obligations with respect to such Confidential Information shall be referred to as the “Receiving Party,” and the Party to whom such confidentiality obligations are owed shall be
referred to as the “Disclosing Party.” 

  

	13.9	 Exceptions: Notwithstanding Paragraphs 13.6 and 13.7, Confidential Information shall not include: (i) information which at the time of disclosure or
acquisition is in the public domain, or which after disclosure or acquisition becomes part of the public domain without violation of this Paragraph 13; (ii) information which at the time of disclosure or acquisition was already in the
possession of the Receiving Party or its employees or 

  

 A-39 

	 	 
agents and was not previously acquired from the Disclosing Party or any of its employees or agents directly or indirectly; (iii) information which the
Receiving Party can show was acquired by such entity after the time of disclosure or acquisition hereunder from a third party without any confidentiality commitment, if, to the best of Receiving Party’s or its employees’ or agent’s
knowledge, such third party did not acquire it, directly or indirectly, from the Disclosing Party or any of its employees or agents; (iv) information independently developed by the Receiving Party without benefit of the Confidential
Information, but specifically excluding the Work Product; and (v) information which is required by Applicable Law or other agencies in connection with the Project, to be disclosed; provided, however, that prior to such disclosure, the Receiving
Party gives reasonable notice to the Disclosing Party of the information required to be disclosed so that the Disclosing Party may attempt to seek an appropriate protective order or other remedy. 

  

	13.10	Equitable Relief. The Parties acknowledge that in the event of a breach of any of the terms contained in this Paragraph 13, the Disclosing Party would suffer irreparable harm
for which remedies at law, including damages, would be inadequate, and that the Disclosing Party shall be entitled to seek equitable relief therefor by injunction, in addition to any and all rights and remedies available to it at law and in equity,
without the requirement of posting a bond. 

  

	13.11	Term. The confidentiality obligations of this Paragraph 13 shall survive the expiration or termination of this Agreement for a period of five (5) years following the
expiration or earlier termination of this Agreement. 

  

	13.12	Disclosure and Filings. Willbros acknowledges that Cheniere may be required from time to time to make filings in compliance with Applicable Law, including filing a copy of
this Agreement with the U.S. Securities and Exchange Commission. 

 14. DISPUTE RESOLUTION 
  

	14.1	Time Requirements for Claims: Should Willbros desire to seek an adjustment to the Guaranteed Maximum Price, the Project Schedule or any other modification to any other
obligation of Willbros under this Agreement for any circumstance that Willbros has reason to believe may give rise to a right to request the issuance of a Change Order, Willbros shall, with respect to each such circumstance:

  

	 	14.1.1	 notify Cheniere in writing within fourteen (14) days of the date that Willbros knew or reasonably should have known of the first occurrence or beginning of
such circumstance. In such notice, Willbros shall state in detail all known and presumed facts upon which its claim is based, including the character, duration and extent of such circumstance, the date Willbros first knew of such circumstance, any
activities impacted by such circumstance, the cost and time consequences of such circumstance (including showing the impact of such circumstance, if any, on the critical path of the Work Plan) and any other details 

  

 A-40 

	 	 
or information that are expressly required under this Agreement. Willbros shall only be required to comply with the notice requirements of this Paragraph
14.1 once for continuing circumstances, provided the notice expressly states that the circumstance is continuing and includes Willbros’ best estimate of the time and cost consequences of such circumstance; and 

  

	 	14.1.2	submit to Cheniere a request for a proposed Change Order as soon as reasonably practicable after giving Cheniere written notice but in no event later than fourteen (14) days
after the completion of each such circumstance, together with a written statement (i) detailing why Willbros believes that a Change Order should be issued, plus all documentation reasonably requested by or necessary for Cheniere to determine
the factors necessitating the possibility of a Change Order and all other information and details expressly required under this Agreement; and (ii) setting forth the effect, if any, which such proposed Change Order would have for the Work on
the Guaranteed Maximum Price and the Project Schedule. 

 The Parties acknowledge that Cheniere will be prejudiced if Willbros
fails to provide the notice required under this Paragraph 14.1, and agree that such requirement is an express condition precedent necessary to any right for an adjustment in the Guaranteed Maximum Price, the Project Schedule, any Work or any other
modification to any other obligation of Willbros under this Agreement. Oral notice, shortness of time, or Cheniere’s actual knowledge of a particular circumstance shall not waive, satisfy, discharge or otherwise excuse Willbros’ strict
compliance with this Paragraph 14.1. 
  

	14.2	Negotiation: In the event that any claim, dispute or controversy arising out of or relating to this Agreement (including the breach, termination or invalidity thereof, and
whether arising out of tort or contract) (“Dispute”) cannot be resolved informally within thirty (30) days after the Dispute arises, either Party may give written notice of the Dispute (“Dispute Notice”) to the other Party
requesting that a representative of Cheniere’s senior management and Willbros’ senior management meet in an attempt to resolve the Dispute. Each such management representative shall have full authority to resolve the Dispute and shall meet
at a mutually agreeable time and place within fourteen (14) days after receipt by the non-notifying Party of such Dispute Notice, and thereafter as often as they deem reasonably necessary to exchange relevant information and to attempt to
resolve the Dispute. In no event shall this Paragraph 14.2 be construed to limit either Party’s right to take any action under this Agreement, including Cheniere’s termination rights. The Parties agree that if any Dispute is not resolved
within thirty (30) days after receipt of the Dispute Notice given in this Paragraph 14.2, then either Party may by notice to the other Party refer the Dispute to be decided by final and binding arbitration in accordance with Paragraph 14.3.

  

	14.3	 Arbitration: Any arbitration held under this Agreement shall be held in Houston, Texas, unless otherwise agreed by the Parties, shall be administered by the
Dallas, Texas office of the American Arbitration Association (“AAA”) and shall, except as otherwise modified by this Paragraph 14.3, be governed by the AAA’s Construction Industry 

  

 A-41 

	 	 
Arbitration Rules and Mediation Procedures (including Procedures for Large, Complex Construction Disputes) (the “AAA Rules”). The number of
arbitrators required for the arbitration hearing shall be determined in accordance with the AAA Rules. The arbitrator(s) shall determine the rights and obligations of the Parties according to the substantive law of the state of Texas, excluding its
conflict of law principles, as would a court for the state of Texas; provided, however, the law applicable to the validity of the arbitration clause, the conduct of the arbitration, including resort to a court for provisional remedies, the
enforcement of any award and any other question of arbitration law or procedure shall be the Federal Arbitration Act, 9 U.S.C.A. § 2. Issues concerning the arbitrability of a matter in dispute shall be decided by a court with proper
jurisdiction. The Parties shall be entitled to engage in reasonable discovery, including the right to production of relevant and material documents by the opposing Party and the right to take depositions reasonably limited in number, time and place,
provided that in no event shall any Party be entitled to refuse to produce relevant and non-privileged documents or copies thereof requested by the other Party within the time limit set and to the extent required by order of the arbitrator(s). All
disputes regarding discovery shall be promptly resolved by the arbitrator(s). This agreement to arbitrate is binding upon the Parties, Willbros’ surety (if any) and the successors and permitted assigns of any of them. At Cheniere’s sole
option, any other person may be joined as an additional party to any arbitration conducted under this Paragraph 14.3, provided that the party to be joined is or may be liable to either Party in connection with all or any part of any Dispute between
the Parties. The arbitration award shall be final and binding, in writing, signed by all arbitrators, and shall state the reasons upon which the award thereof is based. The Parties agree that judgment on the arbitration award may be entered by any
court having jurisdiction thereof. 

  

	14.4	Continued Performance: Notwithstanding any Dispute, so long as Cheniere continues to pay Willbros undisputed amounts in accordance with this Agreement, it shall be the
responsibility of Willbros to continue to prosecute all of the Work diligently and in a good and workmanlike manner in conformity with this Agreement. Except to the extent provided in Paragraph 18, Willbros shall have no right to cease performance
hereunder or to permit the prosecution of the Work to be delayed. Cheniere shall, subject to its right to withhold or offset amounts pursuant to this Agreement, continue to pay Willbros undisputed amounts in accordance with this Agreement; provided,
however, in no event shall the occurrence of any negotiation or arbitration prevent or restrict Cheniere from exercising its rights under this Agreement, at law or in equity, including Cheniere’s right to terminate pursuant to Paragraphs 16 or
17. 

 15. SUSPENSION OF WORK 
  

	15.1	 Suspension of Work: Cheniere may at any time, whether or not for cause, suspend performance of the Work, or any part thereof, by a Change Order specifying
the Work to be suspended and the effective date of such suspension. Willbros shall cease performance of such suspended Work on the effective date of suspension, but shall continue to perform any unsuspended Work and shall take reasonable steps to
minimize 

  

 A-42 

	 	 
any costs associated with such suspension. During any such suspension, Willbros shall take all reasonably necessary actions to maintain and safeguard the
suspended Work in a manner as Cheniere may reasonably require. Except when such suspension ordered by Cheniere is the result of or due to the fault or negligence of Willbros or any Subcontractor or Vendor, Willbros shall be entitled to the
reasonable costs (including actual, but not unabsorbed, overhead, contingency, risk and reasonable profit) of such suspension incurred during the suspension period, including demobilization and remobilization costs and costs incurred for Willbros
Personnel and for Willbros Equipment, at the standby rates, if any, specified in the Letter Agreement, if necessary, along with appropriate supporting documentation to evidence such costs, and a time extension to the Preparation and Material Receipt
Commencement Date, the Construction Commencement Date or the Scheduled Mechanical Completion Date if and to the extent permitted under Paragraph 20.2. In no event shall Willbros be entitled to any additional profits or damages due to such
suspension. 

  

	15.2	Resumption of Work: Unless otherwise instructed by Cheniere, Willbros shall during any such suspension maintain its staff and labor on or near the Work Site and otherwise be
ready to proceed expeditiously with the Work upon receipt of Cheniere’s further instructions. Cheniere may, at any time, authorize resumption of all or any part of the suspended Work by giving notice to Willbros specifying the part of Work to
be resumed and the effective date of such resumption. Suspended Work shall be promptly resumed by Willbros after receipt of such notice. 

 16. TERMINATION AT CHENIERE’S CONVENIENCE 
  

	16.1	Cheniere’s Rights to Terminate for Convenience: Cheniere may, at any time and at its sole convenience, terminate the Agreement or any part of the Work by giving notice
to Willbros specifying the Work to be terminated and the effective date of termination. 

  

	16.2	Obligations upon Termination for Convenience: Should Cheniere issue a termination notice in accordance with Paragraph 16.1, Willbros shall stop performance of the Work
involved on the effective date of termination, unless Cheniere directs Willbros to complete portions of the Work in progress. Such termination shall be effective in the manner specified in the notice, and upon receipt of such notice, Willbros shall,
unless the notice directs otherwise, comply with the obligations set forth in Paragraph 19. Upon such termination, it is agreed that the obligations of this Agreement shall continue as to Work already performed. It is further agreed in the event of
such termination that the amounts due Willbros in full and complete settlement of this Agreement shall be the sum of the following: 

  

	 	16.2.1	The reasonable value of the Work satisfactorily performed prior to termination (the basis of payment being based on the terms of this Agreement, less previous payments, if any, paid
to Willbros under this Agreement), plus 

  

 A-43 

	 	16.2.2	Reasonable direct close-out costs, but in no event shall Willbros be entitled to receive any amount for unabsorbed overhead, contingency or anticipatory profit.

 Willbros shall submit all reasonable direct close-out costs to Cheniere for verification and audit within sixty
(60) days following the effective date of termination. 
 17. TERMINATION BY CHENIERE FOR CAUSE 
  

	17.1	Default by Willbros: Should Willbros at any time: (a) commit a material breach of the Agreement; (b) cause, by any action or omission, any material stoppage or
delay of or interference with the work of Cheniere or its other consultants or contractors; (c) fail to comply with Applicable Law or Applicable Codes and Standards; or (d) become insolvent, have a receiver appointed, make a general
assignment or filing for the benefit of its creditors or file for bankruptcy protection, in which such case of insolvency, receivership or assignment the cure provisions found below shall not apply; then, in any such event and without prejudice to
any other rights available under this Agreement, Cheniere may provide written notice to Willbros specifying the general nature of the default and demanding cure thereof. If, within seven (7) days after receipt of such notice Willbros has failed
to cure such default, or if the default cannot be cured with the exercise of reasonable diligence within such seven (7) days but Willbros fails to commence corrective action and cure such condition within an additional fourteen (14) days,
Cheniere may, at its option: (i) take such steps as are necessary to overcome the default or deficiency stated in its notice, in which case Willbros shall be liable to Cheniere for all related costs in connection therewith (including all
attorneys’ fees, consultant fees and litigation or arbitration expenses) which may be offset by Cheniere at its option; or (ii) terminate for default Willbros’ performance of all or part of the Work. 

  

	17.2	Additional Rights of Cheniere upon Default Termination: In the case of termination for default, Cheniere may, at its option, either itself or through others complete the Work
by whatever method Cheniere may deem expedient, including taking possession, for the purposes of completing the Work, of all Willbros Equipment and materials and/or taking assignment of any or all of Willbros subcontracts or purchase orders for the
Project. In the event of termination under this Paragraph 17, Willbros shall not be entitled to receive any further payment until the Work shall be fully completed and accepted by Cheniere, and Willbros shall be liable to Cheniere for all costs,
damages, losses and expenses (including all attorneys’ fees, consultant fees and litigation or arbitration expenses) incurred by Cheniere in completing the Work, either itself or through others, including all Liquidated Damages to the extent
payable pursuant to Paragraph 21 of this Agreement. 

  

	17.3	Conversion: If any termination for default by Cheniere pursuant to Paragraph 17.1 is found to be not in accordance with the provisions of this Agreement or is otherwise
deemed to be unenforceable, then such termination shall be deemed to be a termination for convenience as provided in Paragraph 16. 

  

 A-44 

 18. TERMINATION BY WILLBROS 
 Should Cheniere fail to pay Willbros undisputed invoiced amounts when due under this Agreement, Willbros may demand in writing that Cheniere comply with the payment terms of this Agreement. If, within forty-five
(45) days after Cheniere’s receipt of such a demand, Cheniere has not taken satisfactory steps to cure such failure, Willbros may, without prejudice to the exercise of any other rights or remedies which may be available to it, terminate
this Agreement by giving Cheniere written notice to that effect. Such termination hereunder by Willbros shall be effective on the date specified in Willbros’ termination notice. In the event of termination under this Paragraph 18, Willbros have
the rights (and Cheniere shall make the payments) provided for in Paragraph 16 in the event of a Cheniere termination for convenience. The right of Willbros to terminate this Agreement for cause shall be without prejudice to, and not in lieu of, any
other remedies available to Willbros under this Agreement. 
 19. WILLBROS’ OBLIGATIONS UPON SUSPENSION OR TERMINATION

  

	19.1	Willbros’ Obligations: If the Agreement or any portion of the Work is suspended or terminated as provided in Paragraphs 15, 16, 17, or 18 and if Cheniere so requests,
Willbros shall: 

  

	 	19.1.1	immediately discontinue Work on the date and to the extent specified in the notice; 

  

	 	19.1.2	place no further orders for subcontracts, materials, equipment, or any other items or services except as may be necessary for completion of such portion of the Work as is not
discontinued, thereafter execute only that portion of the Work not terminated (if any); 

  

	 	19.1.3	inventory, maintain and turn over to Cheniere all Willbros Equipment or any other equipment or other items provided by Cheniere for performance of the terminated Work;

  

	 	19.1.4	promptly make every reasonable effort to procure cancellation upon the best terms as are reasonably obtainable under the circumstances and which are satisfactory to Cheniere of any
or all subcontracts, purchase orders and rental agreements to the extent they relate to the performance of the Work that is discontinued unless Cheniere elects to take assignment of any such subcontracts, purchase orders and rental agreements
pursuant to Paragraph 19.2; 

  

	 	19.1.5	cooperate with Cheniere in the transfer of Work Product, including Drawings, licenses and any other items or information and disposition of Work in progress so as to mitigate
damages; 

  

	 	19.1.6	comply with other reasonable requests from Cheniere regarding the terminated Work; 

  

 A-45 

	 	19.1.7	do whatever is necessary to preserve and protect Work in progress, to protect materials, equipment and supplies in transit or at the Work Site for the Project, to comply with any
Applicable Law and any Applicable Codes and Standards, and to minimize all costs to Cheniere and Willbros resulting from such suspension or termination; and 

  

	 	19.1.8	perform all other obligations under Paragraph 17.2. 

  

	19.2	Assignment of Subcontracts and Other Agreements: If the Agreement or any portion of the Work is suspended or terminated as provided in Paragraphs 15, 16, 17, or 18, Cheniere
may, at its sole option, take assignment of any or all subcontracts, purchase orders and rental agreements. 

 20. FORCE
MAJEURE AND CHENIERE-CAUSED DELAY 
  

	20.1	Force Majeure: 

  

	 	20.1.1	Willbros Relief: If the commencement, prosecution or completion of any Work is delayed by Force Majeure, then Willbros shall be entitled to an extension to the Scheduled
Mechanical Completion Date to the extent, if any, permitted under Paragraph 20.1.1.1 and an adjustment to the Guaranteed Maximum Price to the extent, if any, permitted under Paragraph 20.1.1.2, provided that Willbros complies with the notice and
Change Order request requirements in Paragraph 14.1 and the mitigation requirements in Paragraph 20.4. All time extensions to the Project Schedule and adjustments to the Guaranteed Maximum Price for such delays shall be by Change Order implemented
and documented as required under Paragraph 9. 

  

	 	20.1.1.1	Willbros shall be entitled to an extension to the Scheduled Mechanical Completion Date for delay that meets the requirements of Paragraph 20.1.1 if and to the extent such delay
affects the performance of any Work that is on the critical path of the Work Plan and causes Willbros to achieve Mechanical Completion beyond the Scheduled Mechanical Completion Date, but only if Willbros is unable to proceed with other portions of
the Work so as not to cause a delay in the Scheduled Mechanical Completion Date. 

  

	 	20.1.1.2	 Willbros shall be entitled to an adjustment to the Guaranteed Maximum Price for any delay or prevention that meets the requirements of Paragraph 20.1.1, if such
delay or prevention occurs for a continuous period of at least five (5) days in any thirty (30) day period. If Willbros is entitled to such adjustment to the Guaranteed Maximum Price, the adjustment to the Guaranteed Maximum Price shall
only include reimbursement for the standby time for Willbros’ employees and Willbros Equipment and other standby expenses which are incurred by Willbros after the expiration of such five (5) day period and which 

  

 A-46 

	 	 
are caused by such Force Majeure and the effects thereof. Willbros shall take all reasonable measures, pursuant to Paragraph 20.4, to mitigate the standby
and other Force Majeure costs it incurs, and shall cooperate with Cheniere to help overcome such Force Majeure event. Reimbursement for such standby expenses and other Force Majeure costs shall be subject to an aggregate amount of One Million Five
Hundred Thousand Dollars (U.S.$ 1,500,000). 

  

	 	20.1.2	Cheniere Relief. Subject to Paragraph 20.1.3, Cheniere’s obligations under this Agreement shall be suspended to the extent that performance of such obligations is
delayed by Force Majeure, but only if Cheniere notifies Willbros of the existence of such event of Force Majeure within fourteen (14) days after its occurrence and complies with the mitigation requirements in Paragraph 20.4.

  

	 	20.1.3	Payment Obligations: No obligation of a Party to pay moneys under or pursuant to this Agreement shall be excused by reason of Force Majeure. 

  

	20.2	Cheniere-Caused Delay: Should Cheniere or any person or entity acting on behalf of or under the control of Cheniere (including to any third party contractors working in
connection with the Project) delay the commencement, prosecution or completion of the Work, and if such delay is not in any way attributable to Willbros or its Subcontractors or Vendors but is caused by (a) Cheniere’s or such person or
entity’s active interference in the Work, (b) Cheniere’s ordering a Change in the Work (provided that a Change Order has been issued in accordance with Paragraph 9), or (c) Cheniere’s or such person or entity’s failure
to perform its material obligations pursuant to this Agreement, including the failure to provide access to the Work Site in accordance with Paragraph 5.2, then Willbros shall be entitled to an adjustment in the Guaranteed Maximum Price and an
extension to the Scheduled Mechanical Completion Date if (i) such delay affects the performance of any Work that is on the critical path of the Work Plan, (ii) such delay causes Willbros to complete the Work beyond the Scheduled Mechanical
Completion Date, (iii) Willbros is unable to proceed with other portions of the Work so as not to cause a delay in the Scheduled Mechanical Completion Date and (iv) Willbros complies with the notice and Change Order request requirements in
Paragraph 14.1 and the mitigation requirements of Paragraph 20.4. Any adjustment to the Guaranteed Maximum Price shall be for reasonable, additional direct costs incurred by Willbros for such delay meeting the requirements of this Paragraph 20.2,
and any adjustments to the Guaranteed Maximum Price or the Project Schedule shall be recorded in a Change Order. 

  

	20.3	Delay: For the purposes of Paragraph 20, the term “delay” shall include hindrances, disruptions or obstructions, or any other similar term in the industry and the
resulting impact from such hindrances, disruptions or obstructions, including inefficiency, impact, or lost production. 

  

	20.4	Obligation to Mitigate Delay: At all times in the event of a delay, the Parties shall take reasonable actions to mitigate such delay. 

  

 A-47 

 21. LIQUIDATED DAMAGES 
  

	21.1	Liquidated Damages: If Mechanical Completion occurs after the Scheduled Mechanical Completion Date, Willbros shall pay Cheniere in amounts according to the following schedule
for each day of delay until Mechanical Completion occurs (“Liquidated Damages”): 

  

	 	21.1.1	one (1) through thirty (30) days after the Scheduled Mechanical Completion Date: Zero U.S. Dollars ($0) per day; and 

  

	 	21.1.2	thirty-one (31) days through sixty (60) days inclusive after the Scheduled Mechanical Completion Date at Five Thousand Dollars ($5,000) per day; 

 

	 	21.1.3	sixty-one (61) days through ninety (90) days inclusive after the Scheduled Mechanical Completion Date at Seven Thousand Dollars ($7,000) per day; and

  

	 	21.1.4	ninety-one (91) days and thereafter until Mechanical Completion is achieved at Ten Thousand Dollars ($10,000) per day. 

 Provided, however, in no event shall such Liquidated Damages exceed the total sum of Five Hundred Sixty Thousand Dollars ($560,000), provided that such
limitation of liability shall not be construed to limit Willbros’ other obligations or liabilities under this Agreement (including its obligations (i) to complete the Work for the compensation provided under this Agreement, (ii) to
perform all Work required to achieve Start-up and Project Completion, and (iii) with respect to Warranties), nor shall such limitation of liability apply in the event of Willbros’ willful misconduct (including the willful refusal to
perform the Work, willful delay in performing the Work or abandonment of the Work) or gross negligence. 
  

	21.2	Liquidated Damages Not a Penalty: It is expressly agreed that Liquidated Damages payable under this Agreement do not constitute a penalty and that the Parties, having
negotiated in good faith for such specific Liquidated Damages and having agreed that the amount of such Liquidated Damages is reasonable in light of the anticipated harm caused by the breach related thereto and the difficulties of proof of loss and
inconvenience or nonfeasibility of obtaining any adequate remedy, are estopped from contesting the validity or enforceability of such Liquidated Damages. In the event any Liquidated Damages are held to be unenforceable due to the urging by or on
behalf of any member of the Willbros Group, Willbros specifically agrees to pay Cheniere all actual damages incurred by Cheniere in connection with such breach, including any and all consequential damages (such as loss of profits and revenues,
business interruption, loss of opportunity and use) and all costs incurred by Cheniere in proving the same. 

  

	21.3	 Payment of Liquidated Damages: With respect to any Liquidated Damages that accrue, Cheniere, at its sole discretion, may either (i) invoice Willbros for
such owed Liquidated Damages, and within thirty (30) days of Willbros’ receipt of such invoice, Willbros shall 

  

 A-48 

	 	 
pay Cheniere Liquidated Damages, or (ii) withhold from Willbros amounts that are otherwise due and payable to Willbros in the amount of such Liquidated
Damages. In addition, with respect to the achievement of Mechanical Completion, Willbros shall pay Cheniere all Liquidated Damages, if any, owed under this Agreement as a condition precedent to achieving such Mechanical Completion.

 22. PUBLICITY RELEASES 
 Should Willbros or any of its Subcontractors or Vendors desire to publish or release any publicity or public relations materials of any kind relating to the Agreement specifically or the Project generally, Willbros
shall first submit such material to Cheniere for review. Willbros shall not publish or release any such material without Cheniere’s prior consent, such consent not to be unreasonably withheld. 
 23. GOVERNING LAW 
 It is understood that the
Agreement is governed by the laws of the State of Texas except to the extent its conflict of law principles would refer to the law of another jurisdiction, the Parties acknowledge that the laws of Louisiana govern the rights and obligations of the
Parties as to the validity and enforcement of mechanics’ and materialmen’s liens. Only to the extent that either Party may seek relief of the courts pursuant to this Agreement, Cheniere and Willbros each hereby submit to the exclusive
jurisdiction of the federal and state courts located in Houston, Texas, and agree that service of process may be affected upon them by delivery to the addresses given in the Signature Document. 
 24. GENERAL PROVISIONS 
  

	24.1	Assignment: The Agreement shall be binding upon and inure to the benefit of the successors and assigns of the Parties to the Agreement. The Agreement may neither be assigned
nor transferred by either Party, either in whole or in part, without first obtaining the written consent of the other Party, and any attempt to make such an assignment shall be void; provided, however, that Willbros reserves the right to pledge or
assign its rights to payment under this Agreement in accordance with its agreements with its lenders; provided further, however, that in no event shall a pledge or assignment of rights to payment by Willbros create or impose any additional
obligation on Cheniere or otherwise void or preclude any rights or privileges of Cheniere or any member of the Cheniere Group under this Agreement. Notwithstanding the foregoing, Cheniere may freely assign this Agreement, in whole or in part,
without Willbros’ consent to any affiliate or successor of Cheniere or to any third party making a loan to Cheniere or purchasing the Project. 

  

	24.2	 Ownership and Transfer: Cheniere represents that, once title is transferred as provided in this Agreement, it is the sole owner of the Project. Cheniere
further agrees that any future transferee of any interest in the Project will be subject to the releases and limitations of liability set forth in the Agreement such that the total aggregate liability of Willbros to 

  

 A-49 

	 	 
Cheniere and such recipients shall not exceed, relative to any transferee, the limits of liability set forth in the Agreement. 

 

	24.3	No Waiver: No benefit or right accruing to either Party under the Agreement shall be waived unless the waiver is reduced to writing and signed by both Parties. The waiver, in
one instance, of any act, condition or requirement stipulated in the Agreement shall not constitute a continuing waiver or a waiver of any act, condition or requirement or a waiver of the same act, condition or requirement in other instances, unless
specifically so stated. 

  

	24.4	Status of Willbros: Willbros shall be and always remain an independent contractor with respect to the Work performed under the Agreement. Neither Willbros, its
Subcontractors, its Vendors, nor the Willbros Personnel shall be deemed to be the servants, agents or employees of Cheniere. Willbros shall exercise control, management and direction over the details and means of performing the Work and shall be
subject to the directions of Cheniere only with respect to the scope and general results required. 

  

	24.5	Third Party Beneficiaries: This Agreement shall not be deemed for the benefit of any third party nor shall it give any person not a Party to the Agreement any right to
enforce its provisions. 

  

	24.6	Survival: The provisions of Paragraphs 9.6, 10, 11, 12, 13, 14, 16, 17, 18, 19, 20 and 23 shall survive the final settlement or termination of the Agreement, for whatever
reason. 

  

	24.7	Severability: Any term or provision of the Agreement judicially determined to be invalid or unenforceable to any entity or circumstance shall be deemed, to such
extent, invalid or unenforceable, but the remainder of the Agreement shall remain unaffected and be enforceable according to its terms. 

  

	24.8	Headings: The headings hereof shall not be considered in interpreting the text of the Agreement and are inserted for convenience of reference only. 

 

	24.9	Further Assurances: Each Party shall perform the acts and execute and deliver the documents and give reasonable assurances necessary to give effect to the provisions of the
Agreement; provided that Cheniere shall only be required to give any such assurances upon a material change in the creditworthiness of Cheniere or upon any other significant adverse change to Cheniere. Any assurances required under this Paragraph
24.9 shall not involve the assumption of obligations greater than those provided for in this Agreement. 

  

	24.10	 Entire Agreement: This Agreement supersedes all previous quotations, proposals, letter agreements, contracts, agreements, understandings and correspondence
between the Parties regarding the Work, and constitutes the entire agreement between the Parties concerning the Work. Notwithstanding the foregoing, the Parties acknowledge that the Letter Agreement shall be simultaneously executed with this
Agreement. No promise, agreement, representation or modification to the Agreement shall be of any force or effect 

  

 A-50 

	 	 
between the Parties unless expressly set forth or provided for in the Agreement, a Change Order or an Amendment. 

  

	24.11	Interpretation: The word “include” or “including” shall mean including without limitation. The words “hereof”, “herein”,
“hereunder” and “hereto” refer to the Agreement as a whole, including the Schedules, and not to any particular provision of the Agreement unless expressly indicated. Unless the context clearly requires otherwise, references to
the plural include the singular and the singular the plural. References to “days” or a “day” shall mean a calendar day, unless otherwise stated. Where a Party’s approval or acceptance is required, such approval or acceptance
shall not be unreasonably delayed. 

  

	24.12	Lender Requirements: In addition to other assurances provided in this Agreement, Willbros acknowledges that Cheniere has obtained or may obtain financing, which may be
project financing, associated with the Work, and Willbros agrees to cooperate with Cheniere and Cheniere’s lenders in connection with such Project financing, including entering into direct agreements with such lenders, as reasonably required by
such lenders, covering matters that are customary in project financings of this type such as lender assignment or security rights with respect to this Agreement, consent agreements, opinions of counsel, direct notices to lender and lender’s
independent engineer, step-in/step-out rights, access by lender’s representative, including lender’s independent engineer, and other matters applicable to such Project financing. Willbros shall cooperate with any independent engineer
retained by Cheniere’s lender(s) in the conduct of such independent engineers’ duties in relation to the Project, including the Work. No review, approval or disapproval by any independent engineer shall serve to reduce or limit the
liability of Willbros to Cheniere under this Agreement. 

  

	24.13	Counterparts: This Agreement may be signed in any number of counterparts and each counterpart shall represent a fully executed original as if signed by each of the Parties.
Facsimile signatures shall be deemed as effective as original signatures. 

  

	24.14	Priority. The documents that form this Agreement are listed below in order of priority, with the document having the highest priority listed first and the one with the lowest
priority listed last. Subject to Paragraph 1.6 under the definition of Applicable Codes and Standards regarding conflicts or inconsistencies between any Applicable Codes and Standards, in the event of any conflict or inconsistency between a
provision in one document and a provision in another document, the document with the higher priority shall control. In the event of a conflict or inconsistency between provisions contained within the same document, then the provision that requires
the highest standard of performance on the part of Willbros shall control. This Agreement is composed of the following documents, which are listed in priority: 

  

	 	24.14.1	Change Orders or Amendments to this Agreement; 

  

	 	24.14.2	The Signature Document; 

  

 A-51 

	 	24.14.3	This Schedule “A”; and 

  

	 	24.14.4	All other Schedules and Attachments to this Agreement. 

 END OF SCHEDULE “A”  
  

 A-52 

 ATTACHMENT I 
 WILLBROS’ PARENT GUARANTEE 
 This GUARANTEE (this “Guarantee”) effective
February 01, 2006, is made by Willbros USA, Inc. organized under the laws of the State of Delaware (“Guarantor”), in favor of Cheniere Sabine Pass Pipeline Company, a company organized under the laws of the State of
Delaware (“Owner,” and, together with Guarantor, each a “Party” and, collectively, the “Parties”). Capitalized terms used, but not otherwise defined, herein shall have the
respective meanings ascribed to such terms in the Agreement (as defined below). 
 RECITALS 
 WHEREAS, Owner has agreed to enter into the Agreement for the Engineering, Procurement and Construction of the 42-inch Sabine Pass Pipeline dated
February 01, 2006, with Willbros Engineers, Inc. (“Willbros”) for the engineering, procurement, construction, commissioning, start-up and testing of the 42-inch Sabine Pass Pipeline Project (the
“Project”) located in Cameron Parish, Louisiana and a letter agreement dated February 01, 2006, with Willbros (collectively, the “Agreement”), which are hereby incorporated by reference in this
Guarantee and made a part hereof; and 
 WHEREAS, Willbros is a subsidiary of Guarantor; and 
 WHEREAS, it is a condition to Owner and Willbros’ entering into the Agreement that Guarantor execute and deliver this Guarantee. 

NOW THEREFORE, in consideration of the promises and other good and valuable consideration, the receipt and sufficiency of which are hereby
acknowledged, the Parties hereby agree as follows: 
 1. Guarantee. 
 (a) On the terms and subject to the conditions contained herein, Guarantor hereby unconditionally and irrevocably guarantees, to and for the benefit of
Owner, the full and punctual performance and payment, as and when each such payment or performance becomes due (whether at the stated due date, by acceleration or otherwise), by or on behalf of Willbros of any and all obligations or amounts owed by
Willbros to Owner in connection with and to the extent provided for in the Agreement (the “Guaranteed Obligations”). The Guaranteed Obligations of Guarantor hereunder are direct and primary obligations. 
 (b) This Guarantee is an unconditional, present, and continuing guarantee of performance and payment, and not of collection, is in no way conditioned or
contingent upon any attempt to collect from or enforce performance or payment by Willbros or upon any other event, contingency or circumstance whatsoever, and shall remain in full force and effect and be binding upon and against Guarantor and its
successors and permitted assigns (and shall inure to the benefit of Owner and its successors, endorsees, transferees, and permitted assigns), without 

  

 A-53 

 
regard to the validity or enforceability of the Agreement. If, for any reason, Willbros shall fail or be unable duly, punctually, and fully to perform or
pay, as and when such performance or payment is due, any of the Guaranteed Obligations, Guarantor shall promptly perform or pay, or cause to be performed or paid, such Guaranteed Obligations. 
 (c) Guarantor agrees that any judgment from any litigation (or any award resulting from any arbitration, if Owner and Willbros should agree to arbitrate)
between Willbros and Owner under the Agreement (whether in contested litigation or arbitration, by default or otherwise) shall be conclusive and binding on the Parties for the purposes of determining Guarantor’s obligations under the Guarantee.

 (d) Guarantor further agrees to pay to Owner any and all costs, expenses (including, without limitation, all reasonable fees and
disbursements of counsel), and damages which may be paid or incurred by Owner in enforcing any rights with respect to this Guarantee, including, without limitation, collecting against Guarantor under this Guarantee. 
 2. Obligations Unconditional, Continuing; Etc. 
 Guarantor agrees that the obligations of Guarantor set forth in this Guarantee shall be direct obligations of Guarantor, and such obligations shall be irrevocable and unconditional, shall not be subject to any counterclaim, set-off,
deduction, diminution, abatement, recoupment, suspension, deferment, reduction or defense (other than full and strict compliance with its obligations hereunder) based upon any claim Guarantor or any other person may have against Owner or any other
person and shall remain in full force and effect without regard to and shall not be released, discharged or in any way affected or impaired by, any circumstance or condition whatsoever (other than full and strict compliance by Guarantor with its
obligations hereunder) (whether or not Guarantor shall have any knowledge or notice thereof), including, without limitation: (i) any amendment or modification of or supplement to or other change in the Agreement or any other document,
including, without limitation, any change order, renewal, extension, acceleration or other changes to payment terms thereunder; (ii) any failure, omission or delay on the part of Owner or any other person to confirm or comply with any term of
the Agreement, (iii) any waiver, consent, extension, indulgence, compromise, release or other action or inaction under or in respect of the Agreement or any other document or any obligation or liability of Owner or any other person, or any
exercise or non-exercise of any right, remedy, power, or privilege under or in respect of any such instrument or agreement or any such obligation or liability, other than as expressly set forth in writing executed by Owner and Guarantor;
(iv) any bankruptcy, insolvency, reorganization, arrangement, readjustment, liquidation, or similar proceeding with respect to Owner, Willbros or any other person or any of their respective properties, or any action taken by any trustee or
receiver or by any court in any such proceeding; (v) any discharge, termination, cancellation, invalidity or unenforceability, in whole or in part, of the Agreement or any other document or any term or provision thereof; (vi) any merger or
consolidation of Guarantor or Willbros into or with any other person or any sale, lease, or transfer of all or any of the assets of Guarantor or Willbros; (vii) any change in the ownership of Guarantor or Willbros; (viii) any winding up or
dissolution of Willbros; or (ix) to the extent permitted under Applicable Law, any other occurrence or circumstance whatsoever, whether similar or dissimilar to the foregoing, which might otherwise constitute a legal or 

  

 A-54 

 
equitable defense or discharge of the liabilities of guarantor or surety or which might otherwise limit recourse against Guarantor. Guarantor reserves the
right to (a) set-off against any payment that has become due and payable by the Owner to Willbros under the Agreement and (b) assert defenses which Willbros may have under or with respect to the Agreement to performance of any Guaranteed
Obligations other than defenses arising from the bankruptcy or insolvency of Willbros or Willbros’ failure to have the authority to (x) execute or deliver the Agreement or (y) perform its obligations under the Agreement. The
Guaranteed Obligations constitute the full recourse obligations of Guarantor enforceable against it to the full extent of all its assets and properties. Without limiting the generality of the foregoing, Guarantor agrees that repeated and
successive demands may be made and recoveries may be had hereunder as and when, from time to time, Willbros shall fail to perform obligations or pay amounts owed by Willbros under the Agreement and that notwithstanding the recovery hereunder for or
in respect of any given failure to so comply by Willbros under the Agreement, this Guarantee shall remain in full force and effect and shall apply to each and every subsequent such failure. 
 3. Reinstatement. Guarantor agrees that this Guarantee shall be automatically reinstated with respect to any payment made by or on behalf of Willbros
pursuant to the Agreement if and to the extent that such payment is rescinded or must be otherwise restored, whether as a result of any proceedings in bankruptcy or reorganization or otherwise. 
 4. Waiver of Demands, Notices; Etc. Guarantor hereby unconditionally waives, to the extent permitted by Applicable Law: (i) notice of any of the
matters referred to in Paragraph 2 hereof; (ii) all notices which may be required by Applicable Law, or otherwise, now or hereafter in effect, to preserve any rights against Guarantor hereunder, including, without limitation, any demand, proof,
or notice of non-payment or non-performance of any Guaranteed Obligation; (iii) any right to the enforcement, assertion, or exercise of any right, remedy, power, or privilege under or in respect of the Agreement; (iv) notice of acceptance
of this Guarantee, demand, protest, presentment, notice of failure of performance or payment, and any requirement of diligence; (v) any requirement to exhaust any remedies or to mitigate any damages resulting from failure of performance or
payment by Willbros under the Agreement or by any other person under the terms of the Agreement; and (vi) any other circumstance whatsoever which might otherwise constitute a legal or equitable discharge, release, or defense of a guarantor or
surety, or which might otherwise limit recourse against Guarantor. 
 5. No Subrogation. Notwithstanding any performance, payment or payments
made by Guarantor hereunder (or any set-off or application of funds of Guarantor by Owner), Guarantor shall not be entitled to be subrogated to any of the rights of Willbros or of any rights of Owner hereunder, or any collateral, security, or
guarantee or right of set-off held by Owner, for the performance or payment of the obligations guaranteed hereunder, nor shall Guarantor seek or be entitled to assert or enforce any right of contribution, reimbursement, indemnity or any other right
to payment from Willbros as a result of Guarantor’s performance of its obligations pursuant to this Guarantee until all Guaranteed Obligations are performed or paid in full. If any amount shall be paid to Guarantor on account of such
subrogation, contribution, reimbursement or indemnity rights at any time when all of the Guaranteed Obligations and all amounts owing hereunder shall not have been performed and paid in full, such amount shall be held by Guarantor in trust for
Owner, segregated from other funds of Guarantor, and shall, forthwith 

  

 A-55 

 
upon receipt by Guarantor, be turned over to Owner in the exact form received by Guarantor (duly endorsed by Guarantor to Owner, if required), to be applied
against the Guaranteed Obligations, whether or not matured, in such order as Owner may determine. 
 6. Representations and Warranties.
Guarantor represents and warrants that: 
 (a) it is a corporation duly organized and validly existing under the laws of the State of Delaware
and has the corporate power and authority to execute, deliver and carry out the terms and provisions of the Guarantee; 
 (b) the execution,
delivery and performance of this Guarantee will not conflict with, violate or breach the terms of any agreement of Guarantor; 
 (c) no
authorization, approval, consent or order of, or registration or filing with, any court or other governmental body having jurisdiction over Guarantor is required on the part of Guarantor for the execution and delivery of this Guarantee; and

 (d) this Guarantee, when executed and delivered, will constitute a valid and legally binding agreement of Guarantor, except as the
enforceability of this Guarantee may be limited by the effect of any applicable bankruptcy, insolvency, reorganization, moratorium or similar laws affecting creditors’ rights generally and by general principles of equity as they apply to the
Guarantor. 
 7. Miscellaneous. 
 (a) This Guarantee shall inure to the benefit of and be binding upon the Parties hereto and their respective successors and permitted assigns. Guarantor may not assign or transfer this Guarantee or any rights or obligations hereunder
without Owner’s prior written consent. Owner may assign this Guarantee, in whole or part, to any of its affiliates or co-venturers or to any person jointly controlled by Owner and any co-venturers. Furthermore, Owner may assign, pledge
and/or grant a security interest in this Guarantee to any lender without Guarantor’s consent. Except as otherwise provided in this Paragraph 7, nothing herein, express or implied, is intended or shall be construed to confer upon or to give to
any person other than the Parties hereto any rights, remedies, or other benefits. 
 (b) This Guarantee shall be governed by, and construed
in accordance with, the laws of the state of Texas, without giving effect to the principles thereof relating to conflicts of law. 
 (c) The
Parties agree that any claim, dispute, controversy, difference, disagreement, or grievance (of any and every kind or type, whether based on contract, tort, statute, regulation or otherwise) arising out of, connected with, or relating in any way to
this Guarantee (including, without limitation, the construction, validity, interpretation, termination, enforceability or breach of this Guarantee, the relationship of the Parties established by this Guarantee, or any dispute over arbitrability or
jurisdiction) (“Dispute”) shall be decided by final and binding arbitration. Any arbitration held under this Guarantee shall be held in Houston, Texas, unless otherwise agreed by the Parties, shall be administered by the
Dallas, Texas office of the American Arbitration Association (“AAA”) and shall, except as otherwise modified by this Paragraph 7(c), 

  

 A-56 

 
be governed by the AAA’s Construction Industry Arbitration Rules and Mediation Procedures (including Procedures for Large, Complex Construction
Disputes) (the “AAA Rules”). The number of arbitrators required for the arbitration hearing shall be determined in accordance with the AAA Rules. The arbitrator(s) shall determine the rights and obligations of the Parties
according to the substantive law of the state of Texas, excluding its conflict of law principles, as would a court for the state of Texas; provided, however, the law applicable to the validity of the arbitration clause, the conduct of the
arbitration, including resort to a court for provisional remedies, the enforcement of any award and any other question of arbitration law or procedure shall be the Federal Arbitration Act, 9 U.S.C.A. § 2. Issues concerning the arbitrability of
a matter in dispute shall be decided by a court with proper jurisdiction. The Parties shall be entitled to engage in reasonable discovery, including the right to production of relevant and material documents by the opposing Party and the right to
take depositions reasonably limited in number, time and place, provided that in no event shall any Party be entitled to refuse to produce relevant and non-privileged documents or copies thereof requested by the other Party within the time limit set
and to the extent required by order of the arbitrator(s). All disputes regarding discovery shall be promptly resolved by the arbitrator(s). This agreement to arbitrate is binding upon the Parties and the successors and permitted assigns of any of
them. At Owner’s sole option, any other person may be joined as an additional party to any arbitration conducted under this Paragraph 7(c), provided that the party to be joined is or may be liable to either Party in connection with all or any
part of any Dispute between the Parties. The arbitration award shall be final and binding, in writing, signed by all arbitrators, and shall state the reasons upon which the award thereof is based. The Parties agree that judgment on the arbitration
award may be entered by any court having jurisdiction thereof. 
 (d) No modification or amendment of this Guarantee shall be of any force or
effect unless made in writing, signed by the Parties hereto, and specifying with particularity the nature and extent of such modification or amendment. This Guarantee constitutes the entire and only understanding and agreement among the Parties
hereto with respect to the subject matter hereof and cancels and supersedes any prior negotiations, proposals, representations, understandings, commitments, communications, or agreements, whether oral or written, with respect to the subject matter
hereof. 
 (e) All notices, requests and communications to a Party hereunder shall be in writing (including telecopy and/or fax or similar
writing) and shall be sent: 
 If to Owner: 
 Graham A. McArthur 
 Vice President and Treasurer 
 Cheniere Sabine Pass Pipeline 
 717 Texas
Avenue, Suite 3100 
 Houston, Texas 77002 
 Telephone: (713) 659-1361 
 Fax: (713) 659-5459 
  

 A-57 

 If to Guarantor: 
 Gay S. Mayeux 
 Vice President and Assistant Treasurer 
 Willbros USA, Inc. 
 4400 Post Oak Parkway

 Suite 1000 
 Houston, Texas
77027 
 Telephone: (713) 403-8147 
 Fax: (713) 403-8017 
 or to such other address or telecopy number and with such other copies, as such Party may hereafter reasonably specify
by notice to the other Parties. Each such notice, request or communication shall be effective upon receipt, provided that if the day of receipt is not a business day then it shall be deemed to have been received on the next succeeding business day.

 (f) The headings of the several provisions of this Guarantee are inserted for convenience only and shall not in any way affect the meaning
or construction of any provision of this Guarantee. 
 (g) No forbearance or delay by Owner in asserting rights against Willbros shall affect
or impair in any way Guarantor’s obligations hereunder or the rights of Owner hereunder. 
 (h) In addition to other assurances provided
in this Guarantee, Guarantor acknowledges that Owner has obtained or may obtain project financing associated with the Project and Guarantor agrees to cooperate with Owner and its lenders in connection with such project financing, including, but not
limited to, entering into direct agreements with lenders, as required by such lenders, covering matters that are customary in project financings of this type such as lender assignment or security rights with respect to this Guarantee, consent
agreements, opinions of counsel, direct notices to lender and lender’s independent engineer, step-in/step-out rights, access by lenders’ representative, including lender’s independent engineer, and other matters applicable to such
project financing. 
 (i) This Guarantee may be executed in any number of separate counterparts and all of said counterparts taken together
shall be deemed to constitute one and the same instrument. 
 IN WITNESS WHEREOF, the undersigned have duly executed this Guarantee as
of the date first above written. 
  

			
	WILLBROS USA, INC.
		
	 By:
	 	 /s/ William L. Pardue

	 Name:  William L. Pardue

	 Title:    Assistant Corporate Secretary

  

 A-58 

			
	 CHENIERE SABINE PASS PIPELINE
 COMPANY

		
	 By:
	 	 /s/ Robert Keith Teague

	 Name:
	 	 Robert Keith Teague

	 Title:
	 	 President

  

 A-59 

 ATTACHMENT II - 1 
 PAYMENT BOND 
 Bond
No.                     
 KNOW ALL MEN BY
THESE PRESENTS, that                      (hereinafter “Principal”) and
                    , incorporated in the state of              and duly
authorized to do business in Louisiana, (hereinafter “Surety”), are held and firmly bound unto Cheniere Sabine Pass Pipeline Company (hereinafter “Obligee”), and its representatives, successors and assigns, in the sum of
                     Dollars ($            ) for the payment of which sum
well and truly to be made the said Principal and Surety bind themselves, and their respective heirs, administrators, executors, successors and assigns jointly and severally, firmly by these presents. 
 WHEREAS, Principal has been awarded a contract with Obligee for the project known as the 42-inch Sabine Pass Pipeline Project in Cameron Parish, Louisiana
(hereinafter called the “Contract”) and which Contract is hereby referred to and incorporated by express reference as if fully set forth herein. 
 NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION IS SUCH, that if the Principal shall promptly make payment in full to all persons or entities supplying labor, material, services, utilities and equipment, or any other things in the
prosecution of the work provided for in said Contract, and any and all modifications of said Contract that may hereafter be made, and shall indemnify and save harmless said Obligee of and from any and all loss, damage, and expense, including costs
and attorneys’ fees, which the said Obligee may sustain by reason of Principal’s failure to do so, then this obligation shall be null and void; otherwise it shall remain in full force and effect. 
 The Surety agrees that no change, extension of time, alteration, addition, omission, waiver, or other modification of the terms of either the Contract or in the work to
be performed, or in the specifications, or in the plans, or in the contract documents, or any forbearance on the part of either the Obligee or Principal to the other, shall in any way affect its obligation on this Bond, and Surety does hereby waive
notice of any such changes, extensions of time, alterations, additions, omissions, waivers, or other modifications. 
 The Principal and the Surety agree
that this Bond shall inure to the benefit of all persons or entities as supplying labor, material, services, utilities and equipment, or any other things in the prosecution of the work provided for in said Contract, as well as to the Obligee, and
that any of such persons or entities may maintain independent actions upon this Bond in the name of the person or entities bringing any such action. 
 The
parties executing this Bond on behalf of Principal and Surety represent and warrant that they are duly authorized to bind the Principal and Surety respectively. 
  

 A-60 

 IN WITNESS WHEREOF, the above bounden parties have executed this instrument under their several seals this
             day of                     , 200   the
name and corporate seal of each corporate seal of each corporate party being hereto affixed and these presents duly signed by its undersigned representative, pursuant to authority of its governing body. 
  

			
	PRINCIPAL:
	  
		
	 By:
	 	  
	 Title: 
	 	  
	  
	  
	  
	(Principal’s Address)

  

			
	 Witness

	
	  
	 Or Secretary’s Attest

	 [SEAL]

  

			
	SURETY:
	  
		
	 By:
	 	  
	 Title: 
	 	  
	  
	  
	  
	(Surety’s Address)

  

			
	 Witness

	
	  
	 Or Secretary’s Attest

	 [SEAL]

  

			
	 [Attach Power of Attorney executed

	 by attorney-in-fact on behalf of Surety]

  

 A-61 

 ATTACHMENT II - 2 
 DUAL OBLIGEE RIDER FOR PAYMENT BOND 
 This Rider is to be attached to and forms a part of Payment
Bond No.                      issued by
                     (hereinafter referred to as “Surety”), as Surety, on the
             day of                     ,
20     (“Payment Bond”). 
 WHEREAS, on or about the
             day of                 , 200  ,
                     (hereinafter called the “Principal”), entered into a written agreement with (hereinafter called the
“Primary Obligee”) for the construction of                      (hereinafter called the “Contract”); and 
 WHEREAS, the Principal and the Surety executed and delivered to said Primary Obligee the Performance Bond No.
                 (“Performance Bond”) in connection with the Contract; and 
 WHEREAS, the Primary Obligee has requested the Principal and the Surety to execute and deliver this Dual Obligee Rider for Payment Bond and the Principal
and the Surety have agreed to do so. 
 NOW, THEREFORE, the undersigned hereby agree and stipulate that Cheniere Sabine Pass Pipeline Company
shall be a named obligee (hereinafter referred to as “Additional Obligee”) to the Payment Bond, subject to the conditions set forth below: 
 1. In the event of a material default in payment by the Primary Obligee to the Principal under the terms of the Contract, the right of the Additional Obligee to recover hereunder shall be subject to the condition that
the Additional Obligee remedies said material payment default and thereafter continues to make payment to the Principal as required under the terms of the Contract. 
 2. The aggregate liability of the Surety under the Payment Bond, to any or all of the obligees (Primary and Additional Obligees), as their interests may appear, is limited to the total penal sum of the Payment Bond.

 Signed, sealed and dated this             day of
            , 20    . 
  

			
	PRINCIPAL:
	
	  
		
	 By:       
	 	  
	 Title:    
	 	  
	  
	  
	  
	(Principal’s Address)

  

 A-62 

			
	 Witness

	
	  
	 Or Secretary’s Attest

	 [SEAL]

  

			
	SURETY:
	
	  
	 By:
	 	  
	 Title: 
	 	  
	  
	  
	  
	(Surety’s Address)

  

			
	 Witness.

	
	  
	 Or Secretary’s Attest

	 [SEAL]

  

			
	 [Attach Power of Attorney executed

	 by attorney-in-fact on behalf of Surety]

  

 A-63 

 ATTACHMENT II - 3 
 PERFORMANCE BOND 
 Bond
No.                                     
 KNOW ALL MEN BY THESE PRESENTS, that
                                     (hereinafter
“Principal”) and
                                    , incorporated in the
state of                          and duly authorized to do business in Louisiana (hereinafter “Surety”), are
held and firmly bound unto Cheniere Sabine Pass Pipeline Company (hereinafter “Obligee”), and its representatives, successors and assigns, in the sum of
                 Dollars ($                ) for the payment of which
sum well and truly to be made the said Principal and Surety bind themselves, and their respective heirs, administrators, executors, successors and assigns jointly and severally, firmly by these presents. 
 WHEREAS, Principal has been awarded a contract with Obligee for the project known as the 42-inch Sabine Pass Pipeline Project in Cameron Parish, Louisiana
(hereinafter called the “Contract”) and which Contract is hereby referred to and incorporated by express reference as if fully set forth herein. 
 NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION IS SUCH, that if the above bounden Principal shall well and truly perform all the work, undertakings, covenants, terms, conditions, and agreements of said Contract within the time
provided therein and any extensions thereof that may be granted by Obligee, and during the life of any obligation, guaranty or warranty required under said Contract, and shall also well and truly perform all the undertakings, covenants, terms,
conditions, and agreements of any and all modifications of said Contract that may hereafter be made, and shall indemnify and save harmless said Obligee of and from any and all loss, damage, and expense, including costs and attorneys’ fees,
which the Obligee may sustain by reason of Principal’s failure to do so, then this obligation shall be null and void; otherwise it shall remain in full force and effect. 
 The Surety agrees that no change, extension of time, alteration, addition, omission, waiver, or other modification of the terms of either the Contract or in the work to be performed, or in the specifications, or in
the plans, or in the contract documents, or any forbearance on the part of either the Obligee or Surety to the other, shall in any way affect said Surety’s obligation on this Bond, and said Surety does hereby waive notice of any such changes,
extensions of time, alterations, additions, omissions, waivers, or other modifications. The parties executing this Bond on behalf of Principal and Surety represent and warrant that they are duly authorized to bind the Principal and Surety
respectively. 
 IN WITNESS WHEREOF, the above bounden parties have executed this instrument under their several seals this
                 day of                 , 200  ,
the name and corporate seal of each corporate seal of each corporate party being hereto affixed and these presents duly signed by its undersigned representative, pursuant to authority of its governing body. 
  

 A-64 

			
	PRINCIPAL:
	  
		
	 By:
	 	  
	 Title: 
	 	  
	  
	  
	  
	(Principal’s Address)

  

			
	 Witness

	
	  
	 Or Secretary’s Attest

	 [SEAL]

  

			
	SURETY:
	  
		
	 By:
	 	  
	 Title: 
	 	  
	  
	  
	  
	(Surety’s Address)

  

			
	 Witness

	
	  
	 Or Secretary’s Attest

	 [SEAL]

  

			
	 [Attach Power of Attorney executed

	 by attorney-in-fact on behalf of Surety]

  

 A-65 

 ATTACHMENT II - 4 
 DUAL OBLIGEE RIDER FOR PERFORMANCE BOND 
 This Rider is to be attached to and forms a part of
Performance Bond No.                      issued by
                     (hereinafter referred to as “Surety”), as Surety, on the
             day of                     , 20    
(“Performance Bond”). 
 WHEREAS, on or about the             
day of                     , 200  ,
                     (hereinafter called the “Principal”), entered into a written agreement with
                                 (hereinafter called the “Primary
Obligee”) for the construction of                      (hereinafter called the “Contract”); and 
 WHEREAS, the Principal and the Surety executed and delivered to said Primary Obligee the Payment Bond No.
                     (“Payment Bond”) in connection with the Contract; and 
 WHEREAS, the Primary Obligee has requested the Principal and the Surety to execute and deliver this Dual Obligee Rider for Performance Bond and the
Principal and the Surety have agreed to do so. 
 NOW, THEREFORE, the undersigned hereby agree and stipulate that Cheniere Sabine Pass
Pipeline Company shall be a named obligee (hereinafter referred to as “Additional Obligee”) to the Performance Bond, subject to the conditions set forth below: 
 1. In the event of a material default in performance by the Primary Obligee to the Principal under the terms of the Contract, the right of the Additional Obligee to recover hereunder shall be subject to the condition
that the Additional Obligee remedies said material performance default and thereafter continues to perform as required under the terms of the Contract. 
 2. The aggregate liability of the Surety under the Performance Bond, to any or all of the obligees (Primary and Additional Obligees), as their interests may appear, is limited to the total penal sum of the Performance
Bond. 
 Signed, sealed and dated this              day of
                    , 20    . 
  

			
	PRINCIPAL:
	  
		
	 By:
	 	  
	 Title: 
	 	  
	  
	  
	  
	(Principal’s Address)

  

 A-66 

			
	 Witness

	
	  
	 Or Secretary’s Attest

	 [SEAL]

  

			
	SURETY:
	  
		
	 By:
	 	  
	 Title: 
	 	  
	  
	  
	  
	(Surety’s Address)

  

			
	 Witness

	
	  
	 Or Secretary’s Attest

	 [SEAL]

  

			
	 [Attach Power of Attorney executed

	 by attorney-in-fact on behalf of Surety]

  

 A-67 

 ATTACHMENT III 
 MECHANICAL COMPLETION CERTIFICATE 
 Date:                     
 Cheniere
Sabine Pass Pipeline Company 
 717 Texas Avenue, Suite 3100 
 Houston, Texas 77002 
 Attention: Richard E. Keyser 
  

	Re:	Mechanical Completion Certificate – Sabine Pass Pipeline Project Contract, dated as of February 01, 2006 (the “Agreement”), by and between Cheniere
Sabine Pass Pipeline Company (“Cheniere”) and Willbros Engineers, Inc. (“Willbros”) 

 Pursuant
to Paragraph 8.1 of the Agreement, Willbros hereby certifies that it has completed all requirements under the Agreement for Mechanical Completion with respect to the Sabine Pass Pipeline Project (“Project”), including:
(a) the Work is approved by Cheniere as being ready for pre-commissioning and/or commissioning; (b) Willbros has delivered to Cheniere a set of original test and inspection certificates, including hydrostatic test reports, materials
documentation, MAOP establish records, and internal geometry pig results; (c) Willbros has completed all construction, procurement, fabrication, assembly, erection, installation and testing, including final pipeline hydrostatic tests for the
pipeline and all appropriate appurtenances to ensure that such systems were correctly constructed, procured, fabricated, assembled, erected, installed and tested and are capable of being operated safely and reliably within the requirements contained
in this Agreement; (d) Willbros hereby delivers this Mechanical Completion Certificate as required under Paragraph 8.1 of the Agreement; (e) Willbros has dewatered and dried the pipeline to a dewpoint of negative forty degrees Fahrenheit
(-40oF); (f) Willbros has completed all Exception Items in accordance with Paragraph 8.1 of the Agreement; and (g) Willbros has performed all other obligations required under the Agreement for Mechanical Completion. 
 Willbros certifies that it achieved all requirements under the Agreement for Mechanical Completion on
                    , 200  . 
 Attached is all documentation required to be provided by Willbros under the Agreement to establish that Willbros has achieved all requirements under the Agreement for Mechanical Completion, including the required final pipeline hydrostatic
test reports, materials documentation, MAOP establish records, and internal geometry pig results. 
 IN WITNESS WHEREOF, Willbros has
caused this Mechanical Completion Certificate to be duly executed by its authorized representative and delivered as of the date first written above. 
  

			
	WILLBROS ENGINEERS, INC.
		
	 By:
	 	  
	 Name:
	 	  
	 Title:
	 	 Willbros’ Authorized Representative

	 Date:    
	 	  

  

	cc:	Cheniere Sabine Pass Pipeline Company 

	    	717 Texas Avenue, Suite 3100 

	    	Houston, Texas 77002 

	    	Attention: Allan Bartz 

  

 A-68 

 ATTACHMENT IV 
 PROJECT COMPLETION CERTIFICATE 
 Date:                     
 Cheniere
Sabine Pass Pipeline Company 
 717 Texas Avenue, Suite 3100 
 Houston, Texas 77002 
 Attention: Richard E. Keyser 
  

	Re:	Project Completion Certificate – Sabine Pass Pipeline Project Contract, dated as of February 01, 2006 (the “Agreement”), by and between Cheniere
Sabine Pass Pipeline Company (“Cheniere”) and Willbros Engineers, Inc. (“Willbros”) 

 Pursuant
to Paragraph 8.3 of the Agreement, Willbros hereby certifies that it has completed all requirements under the Agreement for Project Completion with respect to the Sabine Pass Pipeline Project (“Project”), including:
(a) the successful achievement of Mechanical Completion of all systems for the Project; (b) the successful achievement of Start-up of all systems for the Project; (c) delivery by Willbros of all documentation required to be delivered
under this Agreement, including any Work Product, Cheniere’s Confidential Information and other documentation; (d) delivery by Willbros to Cheniere of fully executed Final Lien and Claim Waivers in the form of Schedule
“A”, Attachment X – Part 2 of the Agreement; (e) removal from the Work Site all of Willbros Personnel, supplies, waste, materials, rubbish and temporary facilities and restoration of the Work Site to its natural
conditions in accordance with this Agreement, Applicable Law and Applicable Codes and Standards or any other requirements of any Governing Authority; (f) Willbros hereby delivers this Project Completion Certificate as required under Paragraph
8.3 of the Agreement; (g) delivery by Willbros to Cheniere of evidence acceptable to Cheniere that all Subcontractors and Vendors have been fully and finally paid, including fully executed Final Lien and Claim Waivers from all Subcontractors
and Major Vendors in the form of Schedule “A”, Attachment X – Part 4 of the Agreement; (h) Willbros has completed all Exception Items in accordance with Paragraph 8.3 of the Agreement; and
(i) performance of all other obligations required by the Agreement for Project Completion. 
  

	Willbros	certifies that it achieved all requirements under the Agreement for Project Completion on
                    , 200  . 

 Attached is all documentation required to be provided by Willbros under the Agreement to establish that Willbros has achieved all requirements under the Agreement for Project Completion, including the required
Willbros, Subcontractor, and Major Vendor Lien and Claim Waivers. 
 IN WITNESS WHEREOF, Willbros has caused this Project Completion
Certificate to be duly executed by its authorized representative and delivered as of the date first written above. 
  

			
	WILLBROS ENGINEERS, INC.
		
	 By:
	 	  
	 Name:
	 	  
	 Title:
	 	 Willbros’ Authorized Representative

	 Date:    
	 	  

  

	cc:	Cheniere Sabine Pass Pipeline Company 

	    	717 Texas Avenue, Suite 3100 

	    	Houston, Texas 77002 

	    	Attention: Allan Bartz 

  

 A-69 

 ATTACHMENT V 
 START-UP CERTIFICATE 
 Cheniere Sabine Pass Pipeline Company 
 717 Texas Avenue, Suite 3100 
 Houston, Texas 77002 
 Attention: Richard E. Keyser 
  

	Re:	Start-up Certificate – Sabine Pass Pipeline Project Contract, dated as of February 01, 2006 (the “Agreement”), by and between Cheniere Sabine Pass
Pipeline Company (“Cheniere”) and Willbros Engineers, Inc. (“Willbros”) 

 Pursuant to
Paragraph 8.2 of the Agreement, Willbros hereby certifies that it has completed all requirements under the Agreement for Start-up with respect to the Sabine Pass Pipeline Project (“Project”), including: (a) the
successful achievement of Mechanical Completion of all systems for the Project; (b) Cheniere has purged the Project with either natural gas or nitrogen with assistance and support from Willbros as requested; (c) Willbros has completed all
Exception Items in accordance with Paragraph 8.2 of the Agreement; and (d) performance of all other obligations required by the Agreement for Start-up. 
  

	Willbros	certifies that it achieved all requirements under the Agreement for Start-up on
                    , 200  . 

 Attached is all documentation required to be provided by Willbros under the Agreement to establish that Willbros has achieved all requirements under the Agreement for Start-up, including documentation evidencing the
completion of all Exception Items required under Paragraph 8.2. 
 IN WITNESS WHEREOF, Willbros has caused this Start-up Certificate
to be duly executed by its authorized representative and delivered as of the date first written above. 
  

			
	WILLBROS ENGINEERS, INC.
		
	 By:
	 	  
	 Name:
	 	  
	 Title:
	 	 Willbros’ Authorized Representative

	 Date:    
	 	  

  

	cc:	Cheniere Sabine Pass Pipeline Company 

	    	717 Texas Avenue, Suite 3100 

	    	Houston, Texas 77002 

	    	Attention: Allan Bartz 

  

 A-70 

 ATTACHMENT VI 
 CHANGE ORDER FORM 
  

			
		
	PROJECT NAME: 42-inch Sabine Pass Pipeline Project	  	 
		
	COMPANY: Cheniere Sabine Pass Pipeline Company	  	CHANGE ORDER NUMBER: ________________
		
	CONTRACTOR: Willbros Engineers, Inc.	  	DATE OF CHANGE ORDER: ________________
		
	DATE OF AGREEMENT: February 01, 2006	  	

 The Agreement between the Parties listed above is changed as follows: (attach additional documentation
if necessary)  
 Adjustment to price under the Agreement: 
  

				
	 The original Guaranteed Maximum Price was
	  	$	67,670,200
	 Net change by previously authorized Change Orders
(#            )
	  	$	______
	 The Guaranteed Maximum Price prior to this Change Order was
	  	$	______
	 The Guaranteed Maximum Price will be (increased) (decreased) (unchanged) by this Change Order in the amount of
	  	$	______
	 The new Guaranteed Maximum Price including this Change Order will be
	  	$	______

 Adjustment to dates: 
 The Preparation and Material Receipt Commencement Date will be (increased)(decreased)(unchanged) by              (        )
calendar days and as a result of this Change Order is now:                     , 20    . 
 The Construction Commencement Date will be (increased)(decreased)(unchanged) by             
(        ) calendar days and as a result of this Change Order is now:                     ,
20    . 
 The Scheduled Mechanical Completion Date will be (increased)(decreased)(unchanged) by
             (        ) calendar days and as a result of this Change Order is now:
                    , 20    . 
 Other impacts to liability or obligation of Willbros or Cheniere under the Agreement: 
 Upon execution of this Change Order by Cheniere and
Willbros, the above-referenced change shall become a valid and binding part of the original Agreement without exception or qualification, unless noted in this Change Order. Except as modified by this and any previously issued Change Orders, all
other terms and conditions of the Agreement shall remain in full force and effect. This Change Order is executed by each of the Cheniere’s Authorized Representative and Willbros’ Authorized Representative. 
  

 A-71 

					
	CHENIERE SABINE PASS PIPELINE COMPANY	 		 	WILLBROS ENGINEERS, INC.
			
	   	 		 	   
	 Name
	 		 	 Name

	 Cheniere’s Authorized Representative
	 		 	 Willbros’ Authorized Representative

	 Title
	 		 	 Title

	  	 		 	  
	 Date of Signing
	 		 	 Date of Signing

  

 A-72 

 ATTACHMENT VII 
 APPROVED SUBCONTRACTORS AND VENDORS LIST 
 The following Subcontractors and Vendors each having subcontracts or
purchase orders of any tier are approved Subcontractors and Vendors for the following portions of the Work: 
  

	I.	Subcontractors 

 Construction
Subcontractors: 
  

	 	•	 	Willbros RPI, Inc. 

  

	 	•	 	Sunland Construction, Inc. 

  

	 	•	 	Associated Pipe Line Contractors, Inc. 

  

	 	•	 	Gregory & Cook Construction, Inc. 

  

	 	•	 	U.S. Pipeline, Inc. 

 Geotechnical Investigation:

  

	 	•	 	Louis J. Capozzoli & Associates, Inc. 

  

	 	•	 	Professional Service Industries, Inc. (PSI) 

  

	 	•	 	Terracon Consultants, Inc. 

  

	 	•	 	Tulonay-Wong Engineers, Inc. 

 Cathodic Protection
System Design: 
  

	 	•	 	Corrpro Co., Inc. 

  

	 	•	 	Mears/CPG, LLC 

  

	 	•	 	MESA Products, Inc. 

 Pipeline Civil Surveying:

  

	 	•	 	Charley Foster & Associates 

  

	 	•	 	Lonnie Harper & Associates 

  

	II.	Vendors 

 Pipe Mills, DSAW:

  

	 	•	 	Oregon Steel-Spiral Weld 

  

	 	•	 	Oregon Steel/Campipe-DSAW Long Seam 

  

	 	•	 	Europipe/Berg 

  

 A-73 

	 	•	 	ILVA (Taronto, Italy) 

  

	 	•	 	IPSCO, Inc. 

  

	 	•	 	Corinth Pipe Works S.A. (CPW) 

 Pipe Mills, ERW:

  

	 	•	 	American Steel Pipe 

  

	 	•	 	Stupp/Manesmann 

  

	 	•	 	LaBarge 

  

	 	•	 	IPSCO, Inc. 

  

	 	•	 	Lone Star 

 Valves, Ball Mainline: 
  

	 	•	 	Cooper-Cameron/Grove/Modern Supply 

  

	 	•	 	Delta Valve (Valvitralia Group-Italy) 

  

	 	•	 	SISCO Specialty Products, Inc. 

  

	 	•	 	Power Valve International 

 Valves, Control:

  

	 	•	 	Fisher 

  

	 	•	 	Masoneilan 

 General Pipe, Valves and Fittings:

  

	 	•	 	McJunkin 

  

	 	•	 	Wilson Supply 

  

	 	•	 	Redman Supply 

 Bolts, Stud and Gaskets: 

 

	 	•	 	McJunkin 

  

	 	•	 	Wilson Supply 

  

	 	•	 	Redman Supply 

 Fittings and Flanges (Hy Yield):

  

	 	•	 	SISCO 

  

	 	•	 	LaBarge 

  

	 	•	 	Wilson Supply 

 Bends, Induction: 
  

	 	•	 	Bend Tec 

  

 A-74 

	 	•	 	Shaw 

  

	 	•	 	International Piping Systems 

  

	 	•	 	American Pipe Bending 

 Pig Signal: 
  

	 	•	 	TD Williams 

 Launch/Receiver Package: 

 

	 	•	 	Sagebrush 

  

	 	•	 	Pickett 

  

	 	•	 	Big Inch 

 Regulator Package: 
  

	 	•	 	Sagebrush 

  

	 	•	 	Pickett 

  

	 	•	 	Big Inch 

  

 A-75 

 ATTACHMENT VIII 
 ORGANIZATIONAL CHART 
 

 
  

 A-76 

 ATTACHMENT IX 
 CHENIERE’S HEALTH, SAFETY AND ENVIRONMENTAL POLICIES 
  

	1.	General Guidelines 

 Health, safety and safeguarding
of the environment are within Cheniere’s core values. Willbros shall take into consideration health, safety and the environment (“HSE”) throughout execution of the Work. 
 The minimum approach to the management of HSE issues is generally described in this Attachment IX, and Willbros shall comply with such minimum
requirements and, to the extent possible, maintain the highest level of HSE stewardship for Work of this nature during the execution of the Work. At a minimum, the Work and Willbros’ HSE activities and plans shall comply with: (i) all
Applicable Codes and Standards; (ii) all Applicable Laws, including 29 C.F.R. Part 1910, CERCLA, SARA, and all other applicable environmental laws, regulations and requirements; (iii) the FERC Certificate, and (iv) the most current
FERC-authorized Wetland and Waterbody Construction and Mitigation Procedures and the Upland Erosion Control, Re-vegetation, and Maintenance Plan. 
  

	2.	Safety Management 

 Cheniere’s general HSE
policies shall apply to Willbros and its Subcontractors and Vendors performing Work at the Work Site, and shall apply to the fullest extent practical at all other sites where Work is being performed for Cheniere or where Cheniere personnel are
involved. 
 Willbros shall pay the highest regard to safety and shall conform to all safety-related requirements set forth in the Agreement,
including this Attachment IX and Schedule “D”. 
 Willbros shall be responsible for the safe performance of the Work
under the Agreement, including: (i) the safety of all of the employees, agents, representatives and invitees of Willbros and its Subcontractors and Vendors engaged in the performance of the Work; (ii) ensuring that all Willbros Personnel
are familiar with and will apply all applicable HSE rules and regulations; (iii) providing safety incident reports to Cheniere in accordance with the Agreement; (iv) providing a safe working environment at the Work Site; (v) the safe
performance of the Work by all Willbros Personnel; and (vi) ensuring that awareness of the importance of safety is actively promoted at the Work Site. 
  

	3.	Environmental Management 

 Willbros shall pay the
highest regard to protection of the environment and shall carry out environmental management to ensure that the Work is performed in an environmentally sound manner and in compliance with all provisions of the Agreement, including this Attachment
IX, regarding the environment and Applicable Law. 
  

 A-77 

 Willbros’ objective shall be to ensure, through the proper application of its environmental
protection procedures, that the Work is: (i) managed, planned and engineered to minimize any impact upon the environment; (ii) performed and completed without incidents detrimental to the environment; and (iii) performed in full
compliance with the environmental policy objectives. 
  

	4.	Willbros HSE Plan 

 Willbros shall incorporate all
health, safety and environmental requirements of the Agreement, including this Attachment IX, into Willbros’ HSE plan which it shall implement and adhere to during the performance of the Work. 
 Willbros HSE plan shall contain a full description of the safety and environmental rules, procedures, guidelines, and Work instructions applicable at the
Work Site, which Willbros shall use to ensure the safe and environmentally friendly management of the Work. The HSE plan shall cover all phases of the Work and all activities through Final Acceptance and shall specifically describe safety and
environmental management at the Work Site. 
 The HSE plan shall address all safety and environmental matters relevant to the Work, including
the following: (i) safety meetings and safety events; (ii) safety inspections; (iii) training schedule; (iv) safety reviews at the Work Site; (v) construction safety reviews; (vi) all reasonable emergency response
plans, medical emergency plans; (vii) plans to control the possession and use of firearms, alcohol and controlled substances; and (viii) a Spill Prevent, Control and Countermeasure (SPCC) plan. 
 Cheniere, at its sole discretion, may audit Willbros’ performance of the Work to ensure that the Agreement requirements for safety and the
environment are being satisfied in all respects. Any audits performed shall be based upon Willbros’ safety and environmental manual(s), procedures, and plans. Willbros, at its sole cost, shall immediately correct any nonconformance identified
by Cheniere or its auditors. 
  

 A-78 

 ATTACHMENT X – PART 1 
 WILLBROS’ INTERIM LIEN AND CLAIM WAIVER 
 (To be executed by Willbros with
each invoice other than the final invoice) 
 STATE OF LOUISIANA 

	PARISH	OF                     

 The undersigned, Willbros Engineers, Inc. (“Willbros”), has been engaged under a Pipeline Construction Contract with Cheniere Sabine Pass Pipeline Company
(“Cheniere”), to furnish certain materials, equipment, services, and/or labor for the project known as 42-inch Sabine Pass Pipeline Project (the “Project”), which is located in Cameron Parish, State of Louisiana described in more
detail as follows: 
 __________________________________________________________________________________________(the “Property”). 
 Upon receipt of the sum of U.S.$                     (amount
in invoice submitted with this Interim Lien and Claim Waiver), Willbros waives and releases any and all liens or claims of liens against the Project and the Property and all claims, demands, actions, causes of actions or other rights at law, in
contract, tort, equity or otherwise that Willbros has or may have against Cheniere through the date of                     ,
20     (date of the invoice submitted with this Interim Lien and Claim Waiver). Exceptions as follows: 
 __________________________________________________________________________________________________________ 
 __________________________________________________________________________________________________________ 
 (if no
exception entry or “none” is entered above, Willbros shall be deemed not to have reserved any claim.) 
 Willbros represents that all
Subcontractors, Vendors, sub-subcontractors and employees of Willbros have been paid for all work, materials, equipment, services, labor and any other items performed or provided through
                    , 20     (date of last prior invoice) for the Project. Exceptions as follows: 
 _________________________________________________________________________________________________________. 
 (if no exception entry or “none” is entered above, all such payments have been made) 
 This Interim Lien and Claim
Waiver is freely and voluntarily given and Willbros acknowledges and represents that it has fully reviewed the terms and conditions of this Interim Lien and Claim Waiver, that it is fully informed with respect to the legal effect of this Interim
Lien and Claim Waiver, that it has voluntarily chosen to accept the terms and conditions of this Interim Lien and Claim Waiver in return for the payment recited above. 
  

									
	 FOR WILLBROS:
 Applicable to
Invoice(s) No.         
	 		 	
				
	 Signed:
	 	  	 		 	(SEAL)
	By:	 	  	 		 		 	
	 Title:    
	 	  	 		 		 	
	 Date:    
	 	  	 		 		 	

 AFFIDAVIT 
 On this      day of                     ,
20     , before me appeared the above-signed, known or identified to me personally, who, being first duly sworn, did say that s/he is the authorized representative of Willbros and that this document was signed under oath
personally and on behalf of Willbros. 
 ____________________ 
 Notary Public 
 My term expires
(date):                     
  

 A-79 

 ATTACHMENT X – PART 2 
 WILLBROS’ FINAL LIEN AND CLAIM WAIVER 
 (To be executed by Willbros with the
invoice for final payment) 
 STATE OF LOUISIANA 
 PARISH
OF                     
 The undersigned,
Willbros Engineers, Inc. (“Willbros”), has been engaged under an agreement with Cheniere Sabine Pass Pipeline Company (“Cheniere”), to furnish certain materials, equipment, services, and/or labor for the project known as the
42-inch Sabine Pass Pipeline Project (“Project”), which is located in Cameron Parish, State of Louisiana and more particularly described as follows: 
 __________________________________________________________________________________________(the “Property”). 
 Upon receipt of the sum of
U.S.$                     (amount in invoice for final payment submitted with Willbros’ Final Lien and Claim Waiver), Willbros waives and
releases all liens or claims of liens against the Project and the Property and all claims, demands, actions, causes of actions or other rights at law, in contract, tort, equity or otherwise that Willbros has, may have had or may have in the future
against Cheniere arising out of the agreement or the Project, whether or not known to Willbros at the time of the execution of this Final Lien and Claim Waiver. 
 Willbros represents that all of its obligations, legal, equitable, or otherwise, relating to or arising out of its work on the agreement, Project or subcontracts have been fully satisfied (except for that work and obligations that survive
the termination or expiration of the agreement, including warranties and correction of defective services), including, but not limited to payment to Subcontractors, Vendors and employees and payment of taxes. 
 This Final Lien and Claim Waiver is freely and voluntarily given, and Willbros acknowledges and represents that it has fully reviewed the terms and conditions of this
Final Lien and Claim Waiver, that it is fully informed with respect to the legal effect of this Final Lien and Claim Waiver, and that it has voluntarily chosen to accept the terms and conditions of this Final Lien and Claim Waiver in return for the
payment recited above. Willbros understands, agrees and acknowledges that, upon payment, this document waives rights unconditionally and is fully enforceable to extinguish all claims of Willbros as of the date of execution of this document by
Willbros. 
  

									
	 FOR WILLBROS:
 Applicable to Invoice No(s): ALL (If all, print “all”)
	 		 	
				
	 Signed:
	 	  	 		 	(SEAL)
	By:	 	  	 		 		 	
	 Title:    
	 	  	 		 		 	
	 Date:    
	 	  	 		 		 	

 AFFIDAVIT 
 On this      day of                     ,
20    , before me appeared the above-signed, known or identified to me personally, who, being first duly sworn, did say that s/he is the authorized representative of Willbros and that this document was signed under oath
personally and on behalf of Willbros. 
 ____________________________ 
 Notary Public 
 My term expires
(date):                     
  

 A-80 

 ATTACHMENT X – PART 3 
 SUBCONTRACTORS’ INTERIM LIEN AND CLAIM WAIVER 
 (To be executed by
Subcontractor or Major Vendor [as applicable] with each invoice other than the final invoice) 
 STATE OF LOUISIANA

	PARISH	OF
                                 

 The undersigned,
                                        
                     (“Subcontractor”) who has, under an agreement with Willbros Engineers, Inc. (“Willbros”), furnished
certain materials, equipment, services, and/or labor for the project known as the 42-inch Sabine Pass Pipeline Project (the “Project”), which is located in Cameron Parish, State of Louisiana described in more detail as follows: 

                                      
                                        
                                        
                                   (the “Property”). 

Upon receipt of the sum of
U.S.$                                       
  (“Current Payment”), Subcontractor waives and releases any and all liens or claims of liens against the Project and the Property and all claims, demands, actions, causes of action or other rights at law, in contract, tort, equity
or otherwise that Subcontractor has or may have against Cheniere Sabine Pass Pipeline Company (“Cheniere”) and Willbros through the date of
                                        ,
20         (“Current Date”). Exceptions as follows: 
                                       
                                        
                                        
                                        
                                        
       . 
 (if no exception entry or “none” is entered above, Subcontractor shall be deemed not to have reserved
any claim.) 
 Subcontractor further represents that all employees, laborers, materialmen, sub-subcontractors and subconsultants employed by Subcontractor in
connection with the Project have been paid for all work, materials, equipment, services, labor and any other items performed or provided through
                                        ,
20         (date of last prior Invoice). Exceptions as follows: 
                                       
                                        
                                        
                                        
          . 
 (if no exception entry or “none” is entered above, all such payments have been
made) 
 This Subcontractor’s Interim Lien and Claim Waiver is freely and voluntarily given and Subcontractor acknowledges and represents that it has
fully reviewed the terms and conditions of this Subcontractor’s Interim Lien and Claim Waiver, that it is fully informed with respect to the legal effect of this Subcontractor’s Interim Lien and Claim Waiver, that it has voluntarily chosen
to accept the terms and conditions of this Subcontractor’s Interim Lien and Claim Waiver in return for the payment recited above. 
 FOR
SUBCONTRACTOR : 
 Applicable to Invoice(s) No.          
  

							
				
	Signed:	 	  	 		 	 (SEAL)

				
	By:	 	  	 		 	
				
	Title:	 	  	 		 	
				
	Date:	 	  	 		 	

 AFFIDAVIT 
 On this          day of                     ,
20    , before me appeared the above-signed, known or identified to me personally, who, being first duly sworn, did say that s/he is the authorized representative of Subcontractor and that this document was signed
under oath personally and on behalf of Subcontractor. 
 ______________________________ 
 Notary Public 
 My term expires (date):                              
  

 A-81 

 ATTACHMENT X – PART 4 
 SUBCONTRACTORS’ FINAL LIEN AND CLAIM WAIVER 
 (To be executed by
Subcontractor or Major Vendor [as applicable] with the invoice for final payment) 
 STATE OF LOUISIANA 

	PARISH	OF
                                 

 The undersigned,
                                        
                                        
(“Subcontractor”), has, under an agreement with Willbros Engineers, Inc. (“Willbros”), furnished certain materials, equipment, services, and/or labor for the Project known as the 42-inch Sabine Pass Pipeline Project
(“Project”), which is located in Cameron Parish, State of Louisiana and more particularly described as follows: 
                                       
                                        
                                        
                                        
                       (the “Property”). 
 Upon receipt of the sum of
U.S.$                                      
  , Subcontractor waives and releases any and all liens or claims of liens against the Project and the Property, all claims, demands, actions, causes of action or other rights at law, in contract, tort, equity or otherwise against
Cheniere Sabine Pass Pipeline Company (“Cheniere”) or Willbros, and any and all claims or rights against any labor and/or material bond, which Subcontractor has, may have had or may have in the future arising out of the agreement between
Subcontractor and Willbros, the Project or the Property, whether or not known to Subcontractor at the time of the execution of this Subcontractor’s Final Lien and Claim Waiver. 
 Subcontractor represents that all of its obligations, legal, equitable, or otherwise, relating to or arising out of the agreement between Willbros and Subcontractor, the Project, the Property or sub-subcontracts have
been fully satisfied (except for that work and obligations that survive the termination or expiration of the agreement between Subcontractor and Willbros, including warranties and correction of defective services), including, but not limited to
payment to sub-subcontractors and employees of Subcontractor and payment of taxes. 
 This Subcontractor’s Final Lien and Claim Waiver is freely and
voluntarily given and Subcontractor acknowledges and represents that it has fully reviewed the terms and conditions of this Subcontractor’s Final Lien and Claim Waiver, that it is fully informed with respect to the legal effect of this
Subcontractor’s Final Lien and Claim Waiver, and that it has voluntarily chosen to accept the terms and conditions of this Subcontractor’s Final Lien and Claim Waiver in return for the payment recited above. Subcontractor understands,
agrees and acknowledges that, upon payment, this document waives rights unconditionally and is fully enforceable to extinguish all claims of Subcontractor as of the date of execution of this document by Subcontractor. 
 FOR SUBCONTRACTOR: 
 Applicable to Invoice No(s). ALL (If all,
print “all”) 
  

							
				
	Signed:	 	  	 		 	 (SEAL)

				
	By:	 	  	 		 	
				
	Title:	 	  	 		 	
				
	Date:	 	  	 		 	

 AFFIDAVIT 
 On this          day of                     ,
20    , before me appeared the above-signed, known or identified to me personally, who, being first duly sworn, did say that s/he is the authorized representative of Subcontractor and that this document was signed under
oath personally and on behalf of Subcontractor. 
 ______________________________ 
 Notary Public 
 My term expires (date):                              
  

 A-82 

 SCHEDULE “B” 
 SCOPE OF WORK FOR THE PROJECT 
 TABLE OF CONTENTS

  

			
	 1. PROJECT MANAGEMENT AND ENGINEERING
	  	B-2
	 2. MATERIAL PROCUREMENT
	  	B-3
	 3. CONSTRUCTION MANAGEMENT
	  	B-4
	 4. CONSTRUCTION
	  	B-5
	 5. DELIVERABLES
	  	B-6
	 ATTACHMENT I WORK SITE
	  	B-7
	 ATTACHMENT II FLOW SCHEMATIC
	  	B-8

  

 B-1 

 SCHEDULE “B” 
 SCOPE OF WORK FOR THE PROJECT 
 Willbros shall perform the Project management, engineering,
material procurement, construction management and construction for the Project as described in the Agreement and herein, including providing all deliverables described below. 
 1. PROJECT MANAGEMENT AND ENGINEERING 
 A Willbros project manager shall provide
management and direction for the Project. Project controls shall maintain a detailed Work Plan with activities planned for the Work as set forth in Paragraph 6 of Schedule “A”. Following construction, Willbros will assemble
completion report data, hydrostatic test records, non-destructive testing records, internal geometry pig results, Vendor data and material certifications, MAOP establishment records, and other inspection certificates. 
 Without limiting the generality of the foregoing, the Project management and engineering portion of the Work to be performed by Willbros shall include: 
  

	1.1	Perform Project management, controls and reporting; 

  

	1.2	Prepare design basis document using the following design parameters: 

  

			
	 Class Locations (to be field verified)
	  	
	 Class 1
	  	 MP 0 to MP 11

	 Class 3
	  	 MP 11 to MP 16

	 Design Pressure, psig
	  	 1440

	 Operating Temperature, oF
	  	 20 - 100

	 Corrosion Allowance, inches
	  	 nil

	 Pipe Diameter, inches
	  	 42

	 Pipe W.T. and Grade
	  	
	 F = 0.72
	  	 0.600” API 5L - X70

	 F = 0.60
	  	 0.700” API 5L - X70

	 F = 0.50
	  	 0.864” API 5L - X70

	 External Coatings
	  	
	 FBE
	  	 14 - 16 mils

	 Ruff Coat or equal (for concrete coated pipe)
	  	 3 - 5 mils (in addition to FBE)

	 Abrasion Resistant Coating (for road bores)
	  	 32 mils

	 Internal Liquid Epoxy Coating
	  	 1.5 mils

	 Minimum Bend Radius for Pigging
	  	 5 pipe diameters

	 Concrete Weight Coating
	  	 6” thick, 190 pcf (0.600” W.T. pipe)

		  	 5” thick, 190 pcf (0.864” W.T. pipe)

  

	1.3	Perform population density analysis to finalize class locations; 

  

 B-2 

	1.4	Perform field reconnaissance and gather site specific data at appurtenance locations and crossings, including foreign pipeline crossings; 

  

	1.5	Provide engineering input for permit applications, in accordance with Paragraph 2.3 of Schedule “A”; 

  

	1.6	Perform detailed design of the pipeline and all ancillary facilities of the Project, with reference to the flow schematic located in Attachment II; 

 

	1.7	Prepare Drawings and Specifications with bills-of-materials and construction typicals, in accordance with the Agreement, including Schedule “D”, and Paragraphs 2.7
and 2.8 of Schedule “A”; 

  

	1.8	Modify, as required and in accordance with this Agreement, the Cheniere-provided drawings listed in Paragraph 5.3 of Schedule “A”. 

  

	1.9	Perform geotechnical investigations at monitor-regulator and scraper launcher site; 

  

	1.10	Perform cathodic protection system design; 

  

	1.11	Prepare construction Specifications with hydrostatic test plan, in accordance with Schedule “D”; 

  

	1.12	Prepare job data books which will including hydrostatic test records, welding records, as-built Drawings, certified Vendor Drawings, material certifications, operating and
maintenance instructions for purchased equipment, spare parts lists, Warranties, as-built survey data and results of the internal geometry pig results in an electronic format compatible with the GIS of Cheniere’s choice;

  

	1.13	Provide engineering support during construction, commissioning and Start-up of the Project; and 

  

	1.14	Prepare construction bid solicitation packages, solicit bids, analyze bids and award construction Work to a bidder , in accordance with Paragraphs 3.3, 3.4, and 3.5 of Schedule
“A”. 

 2. MATERIAL PROCUREMENT 
 The procurement portion of the Work to be performed by Willbros shall include: 
  

	2.1	Develop major material Specifications, in accordance with Schedule “D”, and solicit and evaluate bids for such materials; 

  

	2.2	Issue purchase orders for all permanent materials and provide shipping instructions to Vendors; 

  

	2.3	Expedite and coordinate material shipments; 

  

	2.4	Review and approve Vendor Drawings and data submittals; 

  

	2.5	Obtain material certification records; 

  

	2.6	Process material receiving reports and Vendor invoices; 

  

 B-3 

	2.7	Make timely and appropriate payments to Vendors; 

  

	2.8	Perform the following inspections at the Vendor’s plant before material shipment: 

  

	 	2.8.1	Pipe mill (review manufacturing procedures, attend pre-production meeting, and perform inspections during pipe manufacturing); 

  

	 	2.8.2	Fusion-bonded epoxy coating; 

  

	 	2.8.3	Concrete coating; 

  

	 	2.8.4	Launcher skid; and 

  

	 	2.8.5	Monitor regulator skid; 

  

	2.9	Receive, inspect and inventory materials at the Work Site; and 

  

	2.10	Provide recommended spare parts list for commissioning, operations and maintenance (spare parts may, at Cheniere’s sole discretion, be purchased by Cheniere); the cost of such
spare parts is not included within the Guaranteed Maximum Price. 

 3. CONSTRUCTION MANAGEMENT 
 A field office staffed with Willbros Personnel including a field project manager, an office manager/assistant will be established at the Work Site in the Johnson’s
Bayou area, in accordance with Paragraph 4.2 of Schedule “A”. Inspection services will be subcontracted to a qualified firm or self-performed by Willbros in accordance with Paragraph 7 of Schedule “A”. The
construction survey will include a 5-man crew for construction staking and a 2-man and 3-man crew for as-built surveys. These crews will by supervised by Willbros’ chief supervisor. 
 Without limiting the generality of the foregoing, the construction management portion of the Work to be performed by Willbros shall include: 
  

	3.1	Prepare digital alignment maps, showing the pipeline centerline, property ownership and land base information; 

  

	3.2	Prepare road crossing permit Drawings; 

  

	3.3	Perform pre-construction staking for the pipeline, including sites for scraper launcher, monitor regulator station, side valves, mainline valves and other pipeline appurtenances;

  

	3.4	Perform pre- and post-construction topographic civil surveys of the wetlands crossed within the pipeline right-of-way between stations 62+35 and 480+34 to confirm ground contour
restoration at the conclusion of construction is in accordance with the FERC certificate. The surveys will be conducted at the time of restoration and used to ensure compliance prior to demobilization of the construction Subcontractor. Drawing
exhibits with the location of the surveys and cross-sections of the pre- and post-construction transects will be prepared. The pre- and post-construction ground elevation tolerance shall be minus zero (0), plus six (6) inches;

  

 B-4 

	3.5	Perform as-built surveys and prepare as-built Drawings following construction in accordance with Schedule “D” and Paragraphs 2.7 and 2.8 of Schedule
“A”. All survey information shall be geo-referenced. Survey data processing will be performed so that all data collected is delivered in an electronic format compatible with the GIS of Cheniere’s choice; 

 

	3.6	Perform construction inspection through a qualified independent third party to ensure that construction meets the requirements of the Specifications, Drawings, easements, Applicable
Law, Applicable Codes and Standards, permit provisions and all other requirements of construction included in the Agreement; and 

  

	3.7	Provide commissioning and Start-up support, as required by Cheniere, excluding gas handling services. 

 4. CONSTRUCTION 
 The construction portion of the Work to be performed by Willbros or its
Subcontractors shall include: 
  

	4.1	Perform pipeline construction, including clearing, grading, stringing, bending, ditching, laying, welding, coating, tie-ins, lowering-in, backfilling, testing and cleanup;

  

	4.2	Install pipeline monitor regulator station, pig launcher, side valves, mainline valves, and pipeline appurtenances (CP test stations and line markers). The outlet end of the
pipeline will have a weld cap with 2-inch coupling, nipple, plug valve and plug; 

  

	4.3	Perform internal geometry pig survey on the completed pipeline construction prior to the introduction of natural gas or nitrogen to verify that there are no dents with dimensions
greater than what 49 C.F.R. Part 192 or ASME B31.8 codes allow; 

  

	4.4	Install pre-fabricated assemblies, including: 

  

	 	4.4.1	Monitor-regulator station (skid-mounted) on pile-supported platform; 

  

	 	4.4.2	Pig launcher (skid-mounted) on pile-supported platform; and 

  

	 	4.4.3	30-inch NGPL side tap; 

  

	 	4.4.4	42-inch mainline valve assembly; and 

  

	 	4.4.5	42-inch mainline valve and 42-inch side valve; 

  

	4.5	De-water, clean and dry the interior of the pipeline using a series of displacement and cleaning pigs propelled by dry air to achieve a dew point of negative forty degrees
Fahrenheit (-40oF) or less. After drying, the pipeline will be shut-in and pressurized to five (5) psig with dry air. 

  

	4.6	Tie-in pipeline to liquefied natural gas terminal at launcher site; tie-in at Johnson’s Bayou will be by others; 

  

	4.7	Perform site Work at the Work Site, including installation of chain link fence with drive-through and walk gates, grading and installation of rock; 

  

 B-5 

	4.8	Perform Non-destructive testing (NDT) through a qualified third party inspector; radiography inspection shall be performed on 100-percent of girth welds, and a NDT auditor shall be
required; and 

  

	4.9	Cheniere shall provide Willbros access to and use of Cheniere’s dock at the liquefied natural gas terminal for offloading pipe and major equipment skids from barges. Cheniere
shall also provide access to and use of a yard at the liquefied natural gas terminal for staging and pipe storage. Willbros may, with Cheniere’s prior written approval, use an alternate docking facility and/or yard in the Work Site.

 5. DELIVERABLES 
 The following deliverables are considered part of the Work and shall be provided by Willbros during the development and execution of the Project: 
  

	5.1	Drawings (refer to Attachment I of Schedule “D”) 

  

	5.2	Specifications (refer to Attachment II of Schedule “D”) 

  

	5.3	Job Data Book 

  

	 	5.3.1	Hydrostatic tests 

  

	 	5.3.2	Material purchase orders 

  

	 	5.3.3	Material certifications 

  

	 	5.3.4	Certified Vendor Drawings 

  

	 	5.3.5	Operating and maintenance instructions for purchased equipment 

  

	 	5.3.6	Spare parts lists 

  

	 	5.3.7	Warranties 

  

	 	5.3.8	As-built Drawings (with GIS compatible data) 

  

	 	5.3.9	Welder qualifications 

  

	 	5.3.10	Welding procedure(s) 

  

	 	5.3.11	Weld records summary 

  

	 	5.3.12	Internal geometry pig results (with GIS compatible data) 

  

	5.4	Administrative 

  

	 	5.4.1	Monthly progress and cost status reports 

  

	 	5.4.2	Monthly Project Schedule updates 

  

	 	5.4.3	Monthly procurement status reports 

  

	 	5.4.4	Meeting notes 

  

 B-6 

 ATTACHMENT I 
 WORK SITE 
  

	
	

  

	
	 Proposed 42" Natural Gas Pipeline Project
 Sabine Pass
Pipeline Project

  

 B-7 

 ATTACHMENT II 
 FLOW SCHEMATIC 
 

 
  

 B-8 

 SCHEDULE “C” 
 INTENTIONALLY OMITTED 
  

 C-1 

 SCHEDULE “D” 
 APPLICABLE CODES AND STANDARDS, DRAWINGS AND 
 SPECIFICATIONS

 TABLE OF CONTENTS 
  

			
	 1. APPLICABLE CODES AND STANDARDS
	  	D-2
		
	 2. DRAWINGS
	  	D-3
		
	 3. SPECIFICATIONS
	  	D-3
		
	 ATTACHMENT I DRAWINGS
	  	D-4
		
	 ATTACHMENT II SPECIFICATIONS
	  	D-5

  

 D-1 

 SCHEDULE “D” 
 APPLICABLE CODES AND STANDARDS, DRAWINGS AND 
 SPECIFICATIONS

 1. APPLICABLE CODES AND STANDARDS 
 During the execution of the Work, Willbros shall comply with the latest edition of the following Applicable Codes and Standards, irrespective of the specification of any earlier date or edition. In the event of a
conflict between the Applicable Codes and Standards and the Specifications, Willbros shall promptly notify Cheniere of the conflict. The specific Applicable Codes and Standards listed in this Schedule with respect to each organization (e.g., API)
are not meant to be an exclusive list of such Applicable Codes and Standards that must be adhered to with respect to each such organization as they are applicable to the Work. 
  

			
	The Project and all related facilities will be designed in accordance with Part 192, Title 49 of the Code of Federal Regulations “Transportation of Natural and Other Gas By
Pipeline: Minimum Federal Safety Standards” (latest edition).
		
	 AASHTO
	  	 American Association of State Highway and Transportation Officials

	 AISC
	  	 American Institute of Steel Construction

	 ANSI
	  	 American National Standards Institute

	 API
	  	 American Petroleum Institute

	 ASCE
	  	 American Society of Civil Engineers

	 ASME
	  	 American Society of Mechanical Engineers

	 ASTM
	  	 American Society of Testing and Materials

	 AWS
	  	 American Welding Society

	 EPA
	  	 Environmental Protection Agency

	 FM
	  	 Factory Mutual

	 IEEE
	  	 Institute of Electrical and Electronics Engineers

	 IES
	  	 Illuminated Engineering Society

	 ISA
	  	 Instrument Society of America

	 MSS
	  	 Manufacturers Standardization Society of the Valve and Fitting Industry

	 NACE
	  	 National Association of Corrosion Engineers

	 NEMA
	  	 National Electrical Manufacturers Association

	 NFPA
	  	 National Fire Protection Association

	 OSHA
	  	 Occupational Safety and Health Act

	 UBC
	  	 Uniform Building Code

	 UL
	  	 Underwriters Laboratories

	 NEC
	  	 National Electrical Code (NFPA 70)

  

 D-2 

 2. DRAWINGS 
 Willbros shall provide the Drawings listed in Attachment I of this Schedule “D” in accordance with this Agreement. 
 3. SPECIFICATIONS 
 The Specifications include the material/equipment specifications, design
specifications, construction specifications, and inspection specifications included in Attachment II of this Schedule “D”. 
 END OF SCHEDULE “D” 
  

 D-3 

 ATTACHMENT I 
 DRAWINGS 
  

	1.	FERC Alignment Sheets 

  

	2.	Construction Alignment Drawings 

  

	3.	As-Built Alignment Drawings 

  

	4.	Highway Crossing Plan/Profile 

  

	5.	Typical Parish Road Crossing 

  

	6.	Site Specific Wetland Construction Plan 

  

	7.	Hydrostatic Test Profile 

  

	8.	Foreign Pipeline Crossings 

  

	9.	Construction Typicals 

  

	10.	Notes and Legend Sheet 

  

	11.	Scraper Launcher and Inlet Pressure Regulator Plot Plan 

  

	12.	Side Valve Plan and Elevation 

  

	13.	Mainline Valve Plan and Elevation 

  

	14.	Scraper Launcher and Monitor Regulator Platforms 

  

	15.	Pile and Pile Cap Details and Plot Plans 

  

	16.	Fence Standard 

  

	17.	Monitor Regulator Skid Layout 

  

	18.	Scraper Launcher Skid Layout 

  

	19.	Scraper Launcher Piping Hookup Details 

  

	20.	Monitor Regulator Piping Hookup Details 

  

	21.	Pipeline System P&ID 

  

	22.	Valve Operator Details 

  

 D-4 

 ATTACHMENT II 
 SPECIFICATIONS 
  

	1.	Submerged Arc Welded Line Pipe Longitudinal Seam 

  

	2.	Submerged Arc Welded Line Pipe Helical Seam 

  

	3.	Stock Pipe Seamless, SAW and ERW 

  

	4.	Handling, Storage and Shipment of Line Pipe 

  

	5.	Yard Applied Pipe Coating 

  

	6.	Yard Application of Concrete Coating to Pipe 

  

	7.	Internal Coating of Line Pipe 

  

	8.	Induction Bending of Line Pipe 

  

	9.	High Strength Wrought Welding Fittings 

  

	10.	Application of Protective Coating Systems 

  

	11.	Valve Procurement (API 6D, 12-inch and larger) 

  

	12.	Pneumatic Quarter Turn Valve Operators 

  

	13.	Pressure Regulation Valves 

  

	14.	Line Pipe Inspection 

  

	15.	Geotechnical Investigation 

  

	16.	Construction of Pipeline and Related Facilities 

  

	17.	Hydrostatic Test Plan 

  

	18.	Welding Procedures 

  

	19.	As-Built Survey Procedure 

  

 D-5 

 SCHEDULE “E” 
 INTENTIONALLY OMITTED 
  

 E-1 

 SCHEDULE “F” 
 PROJECT SCHEDULE 
  

 F-1 

	
	

  

 F-2 

	
	

  

 F-3

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00099-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00099-of-00352.parquet"}]]