Document:

Exhibit 10.88

 

ASSIGNMENT,
CONSENT AND Subordination

Of
DEVELOPMENT Agreement

 

THIS ASSIGNMENT, CONSENT
AND SUBORDINATION OF DEVELOPMENT AGREEMENT (this “Agreement”) is made as of May 14, 2014, by and among
CDP DEVELOPER I, LLC, a Georgia limited liability company (“Developer”) and UCFP OWNER, LLC, a Delaware
limited liability company; as Trustee under the BR/CDP Colonial Trust Agreement, dated December 15, 2013 (“Borrower”),
for the benefit of KEYBANK NATIONAL ASSOCIATION, a national banking association (together with its successors and assigns as the
lender in respect of the Loan referred to below, “Lender”).

 

RECITALS

 

A.           Borrower
is the owner of that certain tract or parcel of land located lying and being in Orange County, Florida holding title in trust for
the "Beneficiaries" as such term is defined in the BR/CDP Colonial Trust Agreement, dated December 15, 2013 and being
more particularly described on Exhibit A attached hereto and by this reference made a part hereof (the. "Property").
Developer and Borrower are parties to a certain Development Agreement dated January 31, 2014, as the same may have been amended,
supplemented, or modified, a complete copy of which is attached hereto as Exhibit B (the “Development Agreement”).
The Development Agreement describes Developer’s and Borrower’s respective rights and obligations regarding the development
of the Property.

 

B.           Lender
has made or is about to make a loan (the “Loan”) in the principal amount of Twenty-Seven Million Five Hundred
Thousand and No/100 Dollars ($27,500,000.00) to Borrower. In connection with the Loan, Borrower has executed and delivered, or
expects to execute and deliver, to Lender (i) a Promissory Note dated as of the date hereof (as the same may be amended, restated,
supplemented or otherwise modified from time to time, the “Note”), (ii) a Mortgage, Assignment of Rents, Security
Agreement and Fixture Filing dated as of the date hereof (as the same may be amended, restated, supplemented or otherwise modified
from time to time, the “Security Instrument”), (iii) a Construction Loan Agreement dated as of the date hereof
(as the same may be amended, restated, supplemented or otherwise modified from time to time, the “Loan Agreement”),
and (iv) certain other documents evidencing or securing the Loan (as they may be amended, restated, supplemented or otherwise modified
from time to time, such documents, collectively with the Note, the Security Instrument and the Loan Agreement, the “Loan
Documents”).

 

C.           Borrower
has assigned its interest in the Development Agreement to Lender pursuant to this Agreement and certain other Loan Documents;

 

D.           At
Borrower’s request and in order to facilitate Lender’s agreement to make the Loan to Borrower, Developer and Borrower
desire to subordinate the Development Agreement, their respective rights under the Development Agreement and their respective interests
in the Property, if any, to the Security Instrument and the Loan upon the terms and conditions contained in this Agreement.

 

    	 

    	 

    

 

 

E.           Developer
and Borrower intend that the indebtedness evidenced by the Note and the lien and security interests of the Security Instrument
and the Loan Documents be paramount, senior and prior to any and all obligations, expenses and indebtedness owing to Developer
which arise from the Development Agreement and any and all existing liens or future rights to liens of Developer or any person
or entity claiming by, through or under Developer which arise from any and all obligations, expenses and indebtedness owing to
Developer under or in connection with the Development Agreement.

 

NOW THEREFORE, in consideration
of Lender making the Loan, and for other good and valuable consideration, the receipt and sufficiency of which Developer and Borrower
acknowledge, Developer and Borrower agree for the benefit of Lender as follows:

 

1.          Assignment;
Consent. As additional security for the performance by Borrower
of its obligations under the Loan Documents, Borrower hereby assigns, transfers and pledges to Lender, and hereby grants to Lender
a security interest in, all of Borrower’s right, title and interest in, to and under the Development Agreement. Developer
hereby consents to the assignment to Lender of Borrower’s rights under the Development Agreement,
including without limitation Borrower’s interest in all accounts maintained under the Development Agreement. Following the
occurrence and during the continuation of an Event of Default under the Loan Agreement or other Loan Documents, Lender shall be
entitled to exercise any and all rights of Borrower under the Development Agreement in accordance with the terms thereof,
and Developer shall permit and comply in all respects with such exercise. Lender shall have the right to cure any default of Borrower
under the Development Agreement, and may perform any act, duty or obligation required to be performed by Borrower under the Development
Agreement; provided, however, that nothing herein shall require Lender to cure any such default or to perform any
such act, duty or obligation.

 

2.          Subordination. Developer
and Borrower hereby unconditionally subordinate and subject the Development Agreement and all of their respective rights under
the Development Agreement, including, without limitation, any right to receive any amounts or fees (heretofore, now or hereafter
payable) as development fees, development commissions, incentive development fees, affiliate payments, termination fees, liquidated
damages, “key money”,”
reimbursements of advances made by Developer to the owner of the Property or any other compensation,
to the lien of the Security Instrument and Lender’s rights and all remedies under the Loan Documents, including, without
limitation, Lender’s right to receive payments of principal, interest and all other sums due and owing from time to time
under the Loan Documents. Developer and Borrower agree that the rights of Lender under the Security Instrument and the other Loan
Documents are senior and prior to any rights of Developer and Borrower under the Development Agreement. Developer will not receive
or accept any payment under the Development Agreement at any time when Developer has received notice that an Event of Default has
occurred and is continuing under the Loan Agreement or the other Loan Documents. If Developer shall receive any such payment, Developer
shall receive such payment in trust for Lender and immediately deliver the same to Lender.

 

    	Page 2

    	 

    

  

3.          Representations,
Warranties, Acknowledges and Certifications. Developer and Borrower hereby represent, warrant, certify and acknowledge
to Lender as follows: (a) Lender would not make and fund the Loan without the execution and delivery of this Agreement; (b) a true
and complete copy of the Development Agreement (including, without limitation, all modifications and amendments thereto, if any)
is attached to this Agreement as Exhibit B; (c) the Development Agreement represents the entire agreement between Developer
and Borrower with respect to the Property; (d) the Development Agreement is not a lease; (e) Developer has no possessory interest
in the Property; (f) as of the date hereof, no development fees, development commissions, incentive development fees, affiliate
payments, termination fees, liquidated damages, “key money”, reimbursements of advances made by Developer to the owner
of the Property or all other compensation payable to Developer under the Development Agreement are currently due and payable; (g)
Developer has no existing defenses or claims against Borrower with respect to the Development Agreement or any payments due and
owing to Developer thereunder; and (h) as of the date hereof, the Development Agreement is in full force and effect, and to Developer’s
and Borrower’s knowledge, no event of default on the part of either party thereunder, or any event or condition that, with
the giving of notice or the passage of time, or both, would constitute an event of default on the part of either party thereunder,
has occurred and is continuing.

 

4.          Default;
Lender’s Exercise of Rights. Developer and
Borrower agree that upon the occurrence, and during the continuation of, an Event of Default by Borrower (continuing beyond any
applicable notice and grace period) under the Note, the Security Instrument, the Loan Agreement or any of the other Loan
Documents during the term of this Agreement, Lender may take, at Borrower's expense (which shall be reimbursed to Lender upon demand
and shall constitute part of the Secured Obligations (as defined in the Security Instrument) secured by the Security Instrument
and the other Loan Documents), in Lender's own name or in the name of Borrower or either or both of them, such action as Lender
may at any time or from time to time determine to be necessary or appropriate, including, without limitation:

 

a.           exercising
any of the rights of Borrower under the Development Agreement and requiring Developer to attorn to Lender (or its designee);

 

b.           terminating
the Development Agreement upon not less than ten (10) days prior written notice (notwithstanding anything provided for in the Development
Agreement) and requiring Developer to transfer its responsibility for the development of the Property to a development company
selected by Lender in Lender's sole discretion, and Developer shall have no rights or recourse against Lender on account of such
termination (provided, however, that Lender agrees that it will not exercise the foregoing right to terminate the Development Agreement
prior to the earlier of the acquisition by Lender (or its designee) of title to the Property through foreclosure or deed-in-lieu
thereof or the appointment of a receiver for the Property);

 

c.           amending,
modifying or extending the Development Agreement by agreement with Developer (provided, however, that Lender agrees that it will
not exercise the foregoing right with respect to the Development Agreement prior to the earlier of the acquisition by Lender (or
its designee) of title to the Property through foreclosure or deed-in-lieu thereof or the appointment of a receiver for the Property);

 

    	Page 3

    	 

    

 

 

d.           curing
any default by Borrower under the Development Agreement; and

 

e.           otherwise
protecting the rights of Lender hereunder and under the Development Agreement.

 

Lender shall incur no
liability as between itself and Borrower if any action taken by or on its behalf in good faith pursuant hereto shall prove to be,
in whole or in part, inadequate or invalid.

 

BORROWER
and Developer AGREE TO INDEMNIFY AND HOLD HARMLESS LENDER, LENDER’S AFFILIATES AND LENDER’S OFFICERS, DIRECTORS,
EMPLOYEES, AGENTS, ADVISORS, ATTORNEYS AND REPRESENTATIVES (EACH, AN “INDEMNIFIED
PARTY”) FROM AND AGAINST ANY AND ALL CLAIMS, DAMAGES, LOSSES, LIABILITIES AND EXPENSES (each
an “INDEMNIFIED CLAIM”) (INCLUDING, WITHOUT LIMITATION, REASONABLE FEES AND DISBURSEMENTS OF COUNSEL),
JOINT OR SEVERAL, THAT MAY BE INCURRED BY OR ASSERTED OR AWARDED AGAINST ANY INDEMNIFIED PARTY (INCLUDING, WITHOUT LIMITATION,
IN CONNECTION WITH OR RELATING TO ANY INVESTIGATION, LITIGATION OR PROCEEDING OR THE PREPARATION
OF ANY DEFENSE IN CONNECTION THEREWITH), IN EACH CASE ARISING OUT OF OR IN CONNECTION WITH OR RELATING TO The Development Agreement,
THIS AGREEMENT, THE TRANSACTIONS CONTEMPLATED Thereby or HEREBY or any undertaking on lender's part to perform or discharge any
of the terms, covenants or agreements contained in the development agreement, EXCEPT TO THE EXTENT SUCH CLAIM, DAMAGE, LOSS, LIABILITY,
OR EXPENSE IS THE RESULT OF THE GROSS NEGLIGENCE, FRAUD OR WILLFUL MISCONDUCT OF ANY INDEMNIFIED PARTY OR IS THE RESULT
OF ACTIONS TAKEN BY LENDER SUBSEQUENT TO LENDER’S ACQUSITION OF TITLE TO THE PROPERTY BY FORECLOSURE OR DEED IN LIEU THEREOF.
IN THE CASE OF AN INVESTIGATION, LITIGATION OR OTHER PROCEEDING TO WHICH THE INDEMNITY IN THIS PARAGRAPH APPLIES, SUCH INDEMNITY
SHALL BE EFFECTIVE WHETHER OR NOT SUCH INVESTIGATION, LITIGATION OR PROCEEDING IS BROUGHT BY BORROWER OR ANY GUARANTOR OF THE
LOAN, ANY OF THE DIRECTORS, SECURITY HOLDERS OR CREDITORS OF BORROWER OR ANY SUCH GUARANTOR, AN INDEMNIFIED PARTY OR ANY OTHER
PERSON, AND WHETHER OR NOT AN INDEMNIFIED PARTY IS OTHERWISE A PARTY THERETO. THIS INDEMNITY WILL SURVIVE REPAYMENT OF THE LOAN.

 

    	Page 4

    	 

    

 

5.          Attornment;
Right to Terminate. If Lender or any designee or affiliate of Lender shall acquire possession of the Property through judicial
or nonjudicial foreclosure or otherwise, Lender or such designee or affiliate shall have the right to cause Developer to continue
its development of the Property by assuming the obligations of Borrower under the Development Agreement,
but (a) without any liability for any act or omission of Borrower prior to the date of acquisition; (b) without being subject to
any offsets or advances which Developer may have had against Borrower; and (c) without being bound by any agreement or modification
of the Development Agreement entered into without Lender’s prior written consent, such consent not to be unreasonably withheld
or delayed. If Lender or any designee or affiliate of Lender explicitly assumes the obligations of Borrower under the Development
Agreement in writing pursuant to this Section, and if Lender or such designee or affiliate shall thereafter desire to sell the
Property to a third party, then Lender shall either (i) cause such third party to assume the obligations of Borrower under
the Development Agreement; or (ii) terminate the Development
Agreement by written notice to Developer without further obligation thereunder. If a third party shall acquire title to the Property
as a purchaser at a foreclosure sale or otherwise in connection with the exercise of any remedies of Lender under the Loan Documents,
then such third party, immediately upon acquiring title to the Property, shall have the right to cause Developer to continue its
Development of the Property by assuming the obligations of Borrower under the Development Agreement, but subject to the conditions
set forth in clauses (a) through (c) of this Section. Following any assumption by Lender or any designee or affiliate of Lender
or any such third party, in accordance with the terms and conditions of this Section, of the obligations of Borrower under the
Development Agreement, Developer shall recognize such person or entity as the Borrower under the Development Agreement. Upon any
termination or expiration of the Development Agreement, the Developer shall reasonably cooperate with and assist Lender (or its
designee or successor) to effect the transfer to Lender (or its designee or successor) of any and all licenses (including food,
beverage and liquor licenses, if applicable), permits, governmental authorizations, keys, combinations, reservation lists (if applicable),
statements, books & records, insurance policies, documents and/or agreements required for the development or operation of the
Property.

 

6.          Liability
of Lender. Developer agrees that Lender and its successors
and assigns shall not have any liability under the Development Agreement until such time, if any, as Lender or such successor or
assign, as applicable, shall have explicitly assumed the obligations of Borrower under the Development Agreement in writing and
elected to cause Developer to continue its development of the Property. In any such event, Developer
shall look only to the estate and property of Lender or its successors or assigns in the Property for the satisfaction of Developer’s
remedies for the collection of a judgment (or other judicial process) requiring the payment of money in the event of any default
by Lender or its successors or assigns under the Development Agreement, and no other property or assets of Lender (or its successors
or assigns) shall be subject to levy, execution or other enforcement procedure for the satisfaction of Developer’s remedies
under or with respect to the Development Agreement or the relationship of the parties thereunder. If Lender or a successor or assign
explicitly assumes the obligations of Borrower under the Development Agreement in writing or acquires actual physical possession
of the Property, Developer may resign upon not less than thirty (30) days notice to Lender or such successor or assign, as applicable.

 

7.          Notices.
All notices and other communications under this Agreement will be made in writing and given in accordance with this Section
7. All notices, demands, or other communications under this Agreement shall be in writing and shall be delivered to the appropriate
party at the address provided below (subject to change from time to time by written notice to all other parties to this Agreement).
All notices, demands or other communications shall be considered as properly given if delivered personally or sent by first class
United States Postal Service mail, postage prepaid, except that notice of Default may be sent by certified mail, return receipt
requested, or by Overnight Express Mail or by overnight commercial courier service, charges prepaid. Notices so sent shall be effective
three (3) days after mailing, if mailed by first class mail, and otherwise upon receipt; provided, however, that non-receipt of
any communication as the result of any change of address of which the sending party was not notified or as the result of a refusal
to accept delivery shall be deemed receipt of such communication. Each party may establish a new address from time to time by written
notice to the other given in accordance with this Section 7; provided, however, that no change of address will be effective
until written notice thereof actually is received by the party to whom such change of address is sent. Notice to outside counsel
designated by a party entitled to receive notice is for convenience only and is not required for notice to a party to be effective
in accordance with this Section 7:

 

    	Page 5

    	 

    

 

	To Lender:	KEYBANK NATIONAL ASSOCIATION
	 	66 South Pearl St., 5th Floor
	 	MSC: NY-31-66-0567
	 	Albany, NY  12207
	 	Attn: Terry Hill
	 	Direct:  (518) 257-8569
	 	Phone:  (518) 257-8572
	 	 
	With a copy to:  	KEYBANK NATIONAL ASSOCIATION
	 	1200 Abernathy Road, NE, Suite 1550
	 	Atlanta, GA 30328
	 	Attn: Joe Fadus
	 	Direct:  (770 510-2162
	 	Phone:  (770) 510-2195
	 	 
	With a copy to:  	Troutman Sanders LLP
	 	600 Peachtree Street, Suite 5200
	 	Atlanta, GA  30308
	 	Attn:  Jeff Greenway
	 	Phone:  (404) 885-3257
	 	Fax:  (404) 962-6776
	 	 
	To Developer:	c/o Catalyst Development Partners, LLC
	 	880 Glenwood Ave SE
	 	Suite H
	 	Atlanta, Georgia 30316
	 	Attn: Rob Meyer
	 	Phone: (678) 949-9678
	 	Fax: (404) 890-5681
	 	 
	To Borrower:	UCFP Owner, LLC, as Trustee under
	 	the BR/CDP Colonial Trust Agreement
	 	dated December 15, 2013
	 	880 Glenwood Avenue SE, Suite H
	 	Atlanta, GA 30316
	 	Attn:  Rob Meyer
	 	Phone: (678) 949-9678
	 	Fax: (404) 890-5681

 

    	Page 6

    	 

    

 

	With a copy to:	BLUEROCK REAL ESTATE, LLC
	 	712 Fifth Avenue, 9th Floor
	 	New York, NY  10019
	 	Attn: Jordan Ruddy and Michael L. Konig
	 	Phone: (908) 415-8869
	 	Fax: (646) 278-4220
	 	 
	With a copy to:	NELSON MULLINS RILEY & SCARBOROUGH LLP
	 	Atlantic Station
	 	201 17th Street NW, Suite 1700
	 	Atlanta, GA 30363
	 	Attn:  Eric R. Wilensky, Esq.
	 	Phone: (404) 322-6469
	 	Fax: (404) 322-6050
	 	 
	With a copy to:	Hirschler Fleischer
	 	2100 East Cary Street
	 	Richmond, VA  23223
	 	Attn: S. Edward Flanagan, Esq.
	 	Phone:  (804) 771-9592
	 	Fax: (804) 644-0957

 

8.          Governing
Law. THIS AGREEMENT, THE OBLIGATIONS ARISING HEREUNDER, AND ANY CLAIM, CONTROVERSY OR DISPUTE ARISING UNDER OR RELATED
TO THE AGREEMENT, THE RELATIONSHIP OF THE PARTIES, AND/OR THE INTERPRETATION AND ENFORCEMENT OF THE RIGHTS AND DUTIES OF THE PARTIES
SHALL BE GOVERNED BY, AND CONSTRUED IN ACCORDANCE WITH, THE LAWS OF THE STATE OF Georgia
APPLICABLE TO CONTRACTS MADE AND PERFORMED IN SUCH STATE (WITHOUT REGARD TO PRINCIPLES OF CONFLICT OF LAWS) AND ANY APPLICABLE
LAW OF THE UNITED STATES OF AMERICA.

 

9.          Relation
to Development Agreement. In the event of any conflict or discrepancy between any provision in this Agreement and any provision
of the Development Agreement, the applicable provision of this Agreement shall control.

 

10.        Successors
and Assigns. This Agreement shall apply to, bind and inure to the benefit of the parties hereto and their respective successors
and permitted assigns. As used herein “Lender” shall include any subsequent holder of the Security Instrument.

 

11.        Counterparts.
This Agreement may be executed in any number of counterparts, each of which shall be deemed to be an original and all of which
taken together shall constitute one and the same instrument. Signature and acknowledgement pages may be detached from multiple
separate counterparts and attached to a single counterpart so that all signature and acknowledgement pages are physically attached
to the same instrument.

 

[Remainder of Page Intentionally Left Blank]

 

    	Page 7

    	 

    

 

IN WITNESS HEREOF, Developer and
Borrower have caused this Agreement to be duly executed under seal as of the date first set forth above.

 

	 	DEVELOPER:
	 	 
	 	CDP DEVELOPER I, LLC,
	 	a Georgia limited liability company
	 	 
	 	By:	Catalyst Development Partners II, LLC,
	 	 	a Georgia limited liability company

 

	 	By:	/s/ Robert Meyer	[SEAL]
	 	Name:	Robert Meyer	 
	 	Title:	Manager	 

 

Signature
Page

 

    	 

    	 

    

 

	 	BORROWER:
	 	 
	 	UCFP OWNER, LLC, a Delaware limited liability company, as Trustee under the BR/CDP Colonial Trust Agreement dated December 15, 2013

 

	 	By:	/s/ Robert Meyer	[SEAL]
	 		Name:	Robert Meyer	 
	 		Title:	Vice President	 

 

Signature
Page 

 

    	 

    	 

    

 

EXHIBIT A

TO

SUBORDINATION OF DEVELOPMENT AGREEMENT

 

LEGAL DESCRIPTION

 

The land referred to herein below is situated in the County
of ORANGE, State of Florida, and is described as follows:

 

A PORTION OF THE NORTHEAST 1/4 OF SECTION
22, TOWNSHIP 22 SOUTH, RANGE 31 EAST, MORE PARTICULARLY DESCRIBED AS FOLLOWS:

 

COMMENCE AT THE NORTHEAST CORNER OF SAID
NORTHEAST 1/4 OF SECTION 22; THENCE RUN S87°58'03"W ALONG THE NORTH LINE OF SAID NORTHEAST 1/4, A DISTANCE OF 45.02 FEET,
SAID POINT BEING THE INTERSECTION OF A LINE 45.00 FEET WEST OF AND PARALLEL WITH THE EAST LINE OF THE NORTHEAST 1/4 OF SAID SECTION
22 AND THE NORTH LINE OF THE NORTHEAST 1/4 OF SAID SECTION 22; THENCE CONTINUE ALONG SAID NORTH LINE OF THE NORTHEAST 1/4 S87°58'03"W,
A DISTANCE OF 610.44 FEET TO THE POINT OF BEGINNING; THENCE RUN S00°56'14"E, A DISTANCE OF 842.92 FEET TO THE BEGINNING
OF A CURVE CONCAVE TO THE NORTHWEST, HAVING A RADIUS OF 31.00 FEET; THENCE RUN SOUTHWESTERLY ALONG THE ARC OF SAID CURVE THROUGH
A CENTRAL ANGLE OF 98°26'21", AN ARC DISTANCE OF 53.26 FEET; THENCE RUN N82°29'53"W, A DISTANCE OF 41.52 FEET
TO THE BEGINNING OF A CURVE CONCAVE TO THE SOUTH, HAVING A RADIUS OF 109.00 FEET; THENCE RUN WESTERLY ALONG THE ARC OF SAID CURVE
THROUGH A CENTRAL ANGLE OF 12°16'52", AN ARC DISTANCE OF 23.36 FEET; THENCE RUN S07°30'07"W, A DISTANCE OF 287.92
FEET TO THE NORTHERLY RIGHT OF WAY LINE OF STATE ROAD NUMBER 50, AS SHOWN ON THE FLORIDA DEPARTMENT OF TRANSPORTATION RIGHT OF
WAY MAP, SECTION 7506-201, PAGE 9; THENCE RUN N82°29'53"W ALONG SAID NORTHERLY RIGHT OF WAY LINE, A DISTANCE OF 45.95
FEET; THENCE RUN N07°30'07"E, A DISTANCE OF 20.00 FEET; THENCE RUN S82°29'53"E, A DISTANCE OF 2.05 FEET; THENCE
RUN N07°30'07"E, A DISTANCE OF 248.38 FEET TO A POINT ON A NON-TANGENT CURVE CONCAVE TO THE NORTH, HAVING A RADIUS OF
129.00 FEET; THENCE FROM A RADIAL BEARING OF N20°31'47"W, RUN WESTERLY ALONG THE ARC OF SAID CURVE THROUGH A CENTRAL ANGLE
OF 28°01'54", AN ARC DISTANCE OF 63.11 FEET; THENCE RUN N82°29'53"W, A DISTANCE OF 339.09 FEET TO THE BEGINNING
OF A CURVE CONCAVE TO THE SOUTH, HAVING A RADIUS OF 89.50 FEET; THENCE RUN WESTERLY ALONG THE ARC OF SAID CURVE THROUGH A CENTRAL
ANGLE OF 17°07'59", AN ARC DISTANCE OF 26.76 FEET TO A POINT OF COMPOUND CURVATURE OF A CURVE CONCAVE TO THE SOUTH, HAVING
A RADIUS OF 208.50 FEET; THENCE RUN WESTERLY ALONG THE ARC OF SAID CURVE THROUGH A CENTRAL ANGLE OF 18°25'26", AN ARC
DISTANCE OF 67.04 FEET; THENCE RUN N00°56'14"W, A DISTANCE OF 844.21 FEET TO THE SAID NORTH LINE OF THE NORTHEAST 1/4;
THENCE RUN N87°58'03"E ALONG SAID NORTH LINE A DISTANCE OF 634.12 FEET TO THE POINT OF BEGINNING.

 

    	 

    	 

    

  

TOGETHER WITH THE EASEMENT FOR THE BENEFIT
OF THE HEREINABOVE DESCRIBED PROPERTY CONTAINED WITHIN THE EASEMENT AGREEMENT RECORDED IN 0. R. BOOK 10470 AT PAGE 6879 0F THE
PUBLIC RECORDS OF ORANGE COUNTY, FLORIDA.

 

AND:

 

TOGETHER WITH COVENANTS AND NON-EXCLUSIVE
EASEMENTS CONTAINED IN DECLARATION OF COVENANTS, OPERATIONS & RECIPROCAL EASEMENTS RECORDED IN 0. R. BOOK 10498, PAGE 2464,
AS AMENDED BY FIRST AMENDMENT TO DECLARATION OF COVENANTS, OPERATIONS AND RECIPROCAL EASEMENTS RECORDED IN O.R. BOOK 10699, PAGE
7086, OF THE PUBLIC RECORDS OF ORANGE COUNTY, FLORIDA.

 

AND ALSO:

TOGETHER WITH COVENANTS AND NON-EXCLUSIVE EASEMENTS CONTAINED IN AGREEMENT REGARDING EASEMENTS, COVENANTS AND RESTRICTIONS RECORDED
IN 0. R. BOOK 8838, PAGE 3758, AS AMENDED BY FIRST AMENDMENT TO AGREEMENT REGARDING EASEMENTS, COVENANTS AND RESTRICTIONS RECORDED
IN 0. R, BOOK 9338, PAGE 4682, OF THE PUBLIC RECORDS OF ORANGE COUNTY, FLORIDA.

 

AND ALSO:

 

TOGETHER
WITH THE EASEMENTS FOR THE BENEFIT OF THE HEREINABOVE DESCRIBED PROPERTY CONTAINED WITHIN THE RECIPROCAL EASEMENT AGREEMENT RECORDED
IN O.R. BOOK 10699, PAGE 7102, OF THE PUBLIC RECORDS OF ORANGE COUNTY, FLORIDA.

 

    	 

    	 

    

 

EXHIBIT b

TO

SUBORDINATION OF DEVELOPMENT AGREEMENT

 

DEVELOPMENT
AGREEMENT

 

[To Be Attached]Exhibit 10.89

 

CONSTRUCTION
LOAN AGREEMENT

 

for a loan
in the amount of

 

$27,500,000.00

 

MADE BY
AND BETWEEN

 

UCFP OWNER,
LLC, a Delaware limited liability company, 

as Trustee
under the BR/CDP Colonial Trust Agreement dated December 15, 2013

 

AND

 

KEYBANK
NATIONAL ASSOCIATION,

a national banking association,

 

Dated as of
May 14, 2014

 

    	 

    	 

    

 

TABLE OF
CONTENTS

 

	ARTICLE
    1 INCORPORATION OF RECITALS AND EXHIBITS
    	1
	 	 	 
	1.1	Incorporation of Recitals.	1
	1.2	Incorporation of Exhibits.	1
	 	 	 
	ARTICLE
    2 DEFINITIONS	1
	 	 	 
	2.1	Defined Terms.	1
	2.2	Other Definitional Provisions.	11
	 	 	 
	ARTICLE
    3 BORROWER’S REPRESENTATIONS
    AND WARRANTIES	11
	 	 	 
	3.1	Representations and Warranties.	11
	3.2	Survival of Representations and Warranties.	14
	 	 	 
	ARTICLE
    4 LOAN AND LOAN DOCUMENTS	14
	 	 	 
	4.1	Agreement to Borrow and Lend; Lender’s Obligation
    to Disburse.	14
	4.2	Loan Documents.	15
	4.3	Term of the Loan.	16
	4.4	Prepayments.	17
	4.5	Required Principal Payments.	17
	4.6	Late Charge.	18
	 	 	 
	ARTICLE
    5 INTEREST	18
	 	 	 
	5.1	Interest Rate.	18
	 	 	 
	ARTICLE
    6 COSTS OF MAINTAINING LOAN	20
	 	 	 
	6.1	Increased Costs and Capital Adequacy.	20
	6.2	Borrower Withholding.	21
	 	 	 
	ARTICLE
    7 LOAN FEES, EXPENSES AND ADVANCES	21
	 	 	 
	7.1	Loan and Administration Expenses.	21
	7.2	Origination Fee.	22
	7.3	Exit Fee.	22
	7.4	Lender’s Attorneys’ Fees and Disbursements.	22
	7.5	Time of Payment of Fees and Expenses.	22
	7.6	Expenses and Advances Secured by Loan Documents.	22
	7.7	Right of Lender to Make Advances to Cure Borrower’s
    Defaults.	23
	 	 	 
	ARTICLE
    8 NON-CONSTRUCTION REQUIREMENTS PRECEDENT
    TO THE OPENING OF THE LOAN	23
	 	 	 
	8.1	Non-Construction Conditions Precedent.	23
	 	 	 
	ARTICLE
    9 CONSTRUCTION REQUIREMENTS PRECEDENT
    TO THE OPENING OF THE LOAN	25
	 	 	 
	9.1	Required Construction Documents.	25
	 	 	 
	ARTICLE
    10 BUDGET AND CONTINGENCY FUND	26
	 	 	 
	10.1	Budget.	26
	10.2	Budget Line Items.	27
	10.3	Contingency Fund.	27
	10.4	Optional Method for Payment of Interest.	28
	 	 	 
	ARTICLE
    11 SUFFICIENCY OF LOAN	28
	 	 	 
	11.1	Loan In Balance.	28

 

    	 

    	 

    

 

	ARTICLE
    12 CONSTRUCTION PAYOUT REQUIREMENTS	28
	 	 	 
	12.1	Applicability of Sections.	28
	12.2	Monthly Payouts.	29
	12.3	Documents to be Furnished for Each Disbursement.	29
	12.4	Retainages.	30
	12.5	Disbursements for Materials Stored On-Site.	30
	12.6	Disbursements for Offsite Materials.	30
	 	 	 
	ARTICLE
    13 FINAL DISBURSEMENT FOR CONSTRUCTION	31
	 	 	 
	13.1	Final Disbursement for Construction.	31
	 	 	 
	ARTICLE
    14 certain other requirements	32
	 	 	 
	14.1	Deposit Accounts.	32
	14.2	Limitation on Management Fee.	32
	 	 	 
	ARTICLE
    15 OTHER COVENANTS	33
	 	 	 
	15.1	Borrower further covenants and agrees as follows:	33
	15.2	Authorized Representative.	38
	 	 	 
	ARTICLE
    16	38
	 	 	 
	CASUALTIES AND CONDEMNATION	38
	 	 	 
	16.1	Lender’s Election to Apply Proceeds on Indebtedness.	38
	16.2	Borrower’s Obligation to Rebuild and Use
    of Proceeds Therefor.	39
	 	 	 
	ARTICLE
    17 ASSIGNMENTS BY LENDER AND BORROWER	39
	 	 	 
	17.1	Assignments and Participations.	39
	17.2	Prohibition of Assignments and Transfers by Borrower.	40
	17.3	Prohibition of Transfers in Violation of ERISA.	43
	17.4	Successors and Assigns.	43
	 	 	 
	ARTICLE
    18 TIME OF THE ESSENCE	43
	 	 	 
	18.1	Time is of the Essence. Borrower agrees that time
    is of the essence under this Agreement	43
	 	 	 
	ARTICLE
    19 EVENTS OF DEFAULT	43
	 	 	 
	ARTICLE
    20 LENDER’S REMEDIES IN EVENT
    OF DEFAULT	46
	 	 	 
	20.1	Remedies Conferred Upon Lender.	47
	 	 	 
	ARTICLE
    21 GENERAL PROVISIONS	47
	 	 	 
	21.1	Captions.	47
	21.2	Modification; Waiver.	47
	21.3	Governing Law.	47
	21.4	Acquiescence Not to Constitute Waiver of Lender’s
    Requirements.	47
	21.5	Disclaimer by Lender.	47
	21.6	Partial Invalidity; Severability.	48
	21.7	Definitions Include Amendments.	48
	21.8	Execution in Counterparts.	48
	21.9	Entire Agreement.	48
	21.10	Waiver of Damages.	48
	21.11	Claims Against Lender.	48
	21.12	Jurisdiction.	49
	21.13	Set-Offs.	49
	 	 	 
	ARTICLE
    22 NOTICES	51
	 	 	 
	ARTICLE
    23 WAIVER OF JURY TRIAL	52

 

    	- ii -

    	 

    

 

EXHIBITS
TO LOAN AGREEMENT

 

	Exhibit A	Legal Description of Land
	Exhibit B	Permitted Exceptions
	Exhibit C	Title Requirements
	Exhibit D	Form of Survey Certification
	Exhibit E	Insurance Requirements
	Exhibit F	Architect’s Certificate
	Exhibit G	Initial Budget
	Exhibit H	Borrower’s Certificate
	Exhibit I	Soft and Hard Cost Requisition Form
	Exhibit J	Borrower’s Certificate of Compliance
	Exhibit K	LIBOR Notice Election
	Exhibit L	Form of Construction Loan Update Endorsement

 

    	- iii -

    	 

    

 

CONSTRUCTION
LOAN AGREEMENT

 

THIS
CONSTRUCTION LOAN AGREEMENT (“Agreement”) is made as of May 14, 2014, by and between UCFP OWNER, LLC, a Delaware
limited liability company, as Trustee under the BR/CDP Colonial Trust Agreement dated December 15, 2013 (“Borrower”),
and KEYBANK NATIONAL ASSOCIATION, a national banking association, its successors and assigns (“Lender”).

 

WITNESSETH:

 

RECITALS

 

A.           Borrower
is the owner in fee simple of approximately 12.65 acres of land located on East Colonial Drive in the City of Orlando, County
of Orange, State of Florida, and legally described in Exhibit A attached hereto (the “Land”). Borrower
proposes to construct a multi-family project containing approximately 296 Class A apartment units on the Land.

 

B.           Borrower
has applied to Lender for a loan in the amount of up to Twenty-Seven Million Five Hundred Thousand and No/100 Dollars ($27,500,000.00)
(the “Loan”) to finance Borrower’s development and construction of the proposed improvements of the Project,
and Lender is willing to make the Loan on the terms and conditions hereinafter set forth.

 

NOW,
THEREFORE, in consideration of the mutual covenants and agreements herein contained, the parties hereto agree as follows:

 

ARTICLE
1

INCORPORATION OF RECITALS AND EXHIBITS

 

1.1           Incorporation
of Recitals.

 

The
foregoing preambles and all other recitals set forth herein are made a part hereof by this reference.

 

1.2           Incorporation
of Exhibits.

 

Exhibits
A through L, to this Agreement, attached hereto are incorporated in this Agreement and expressly made a part hereof
by this reference.

 

ARTICLE
2

DEFINITIONS

 

2.1          Defined
Terms.

 

The
following terms as used herein shall have the following meanings:

 

Adjusted
LIBOR Rate: An interest rate per annum equal to either the Adjusted One Month LIBOR Rate or the Adjusted Daily LIBOR Rate.

 

Adjusted
Daily LIBOR Rate: An interest rate per annum equal to the sum of (a) the Daily LIBOR Rate plus (b) the LIBOR Rate Margin.
The Adjusted Daily LIBOR Rate shall change immediately and contemporaneously with any change in the Daily LIBOR Rate.

 

    	 

    	 

    

 

Adjusted
One Month LIBOR Rate: An interest rate per annum equal to the sum of (A) the rate obtained by dividing (x) the LIBOR Rate
for such LIBOR Rate Interest Period by (y) a percentage equal to one hundred percent (100%) minus the Reserve Percentage for such
LIBOR Rate Interest Period and (B) the LIBOR Rate Margin.

 

Adjusted
Prime Rate: A rate per annum equal to the sum of (a) the Prime Rate Margin and (b) the greater of (i) the Prime Rate or (ii)
one percent (1%) in excess of the Federal Funds Effective Rate. Any change in the Prime Rate (or the Federal Funds Effective Rate,
as applicable) shall be effective immediately from and after such change in the Adjusted Prime Rate. Notwithstanding anything
to the contrary contained herein, the Adjusted Prime Rate shall not be lowered than the Adjusted LIBOR Rate.

 

Affected
Entity: As such term is defined in Section 17.2.

 

Affiliate:
With respect to a specified person or entity, any individual, partnership, corporation, limited liability company, trust, unincorporated
organization, association or other entity which, directly or indirectly, through one or more intermediaries, controls or is controlled
by or is under common control with such person or entity, including, without limitation, any general or limited partnership in
which such person or entity is a partner.

 

Agreement:
This Construction Loan Agreement.

 

Applicable
Rate: As such term is defined in Section 5.1(a).

 

Applicable
Retention Amount: Amounts withheld by Borrower from a payment to General Contractor pursuant
to the terms and provisions of the General Contract.

 

Appraisal.
An MAI certified appraisal of the Project performed in accordance with FIRREA and Lender’s appraisal requirements by an
appraiser selected and retained by Lender.

 

Architect:
Humphreys & Partners Architects/Florida, L.L.C., a Florida limited liability company

 

Architect’s
Certificate: A certificate in the form of Exhibit F attached hereto executed by the Architect in favor of Lender.

 

Assignment
of Rents: An assignment of leases and rents made by Borrower in favor of Lender assigning all leases, subleases and other
agreements relating to the use and occupancy of all or any portion of the Project, and all present and future leases, rents, issues
and profits therefrom.

 

Assumed
Interest Rate: as of any date, the greatest of (a) six and one-half percent (6.50%) per annum, (b) the yield per annum as
of the date of such calculation on U.S. Treasury securities selected in good faith by Lender, maturing approximately ten (10)
years after the date of calculation, plus 215 basis points per annum, and (c) the Applicable Rate then in effect.

 

Authorized
Representative: As such term is defined in Section 15.2.

 

Bankruptcy
Code: Title 11 of the United States Code entitled “Bankruptcy” as now or hereafter in effect, or any successor
thereto or any other present or future bankruptcy or insolvency statute

 

Bluerock
Operating Partnership: As such term is defined in Section 17.2.

 

BR Member:
As such term is defined in Section 17.2.

 

BR
REIT: As such term is defined in Section 17.2.

 

    	- 2 -

    	 

    

 

BR
SOIF: As such term is defined in Section 17.2.

 

BR/CDP
Venture: As such term is defined in Section 17.2.

 

Breakage
Costs: (a) The cost to Lender of re-employing funds bearing interest at an Adjusted LIBOR Rate, incurred (or expected
to be incurred) in connection with (i) any payment of any portion of the Loan bearing interest at an Adjusted LIBOR Rate
prior to the termination of any applicable LIBOR Rate Interest Period, (ii) the conversion of an Adjusted LIBOR Rate to any
other applicable interest rate on a date other than the last day of the relevant LIBOR Rate Interest Period, or (iii) the
failure of Borrower to draw down, on the first day of the applicable LIBOR Rate Interest Period, any amount as to which Borrower
has elected a LIBOR Rate Option and (b) any amounts payable by Borrower under any Interest Rate Agreement in connection with
termination of such Interest Rate Agreement.

 

Budget:
The budget for the Project specifying all costs and expenses of every kind and nature whatever to be incurred by Borrower in connection
with the Project prior to the Maturity Date.

 

Budget
Line Item: As such term is defined in Section 10.2.

 

Business
Day: A day of the year on which banks are not required or authorized to close in Cleveland, Ohio or Atlanta, Georgia.

 

Catalyst
Member: As such term is defined in Section 17.2.

 

Change
Order: Any request for changes in the Plans and Specifications (other than minor field changes involving no extra cost).

 

Completion
Date: May 14, 2016, subject to extension pursuant to Section 15.1(b).

 

Completion
Guaranty: A guaranty of performance and completion, executed by each Guarantor and pursuant to which the Guarantors jointly
and severally guarantee the lien-free and timely completion of the Project in accordance with all provisions of this Agreement
and Borrower’s obligation to keep the Loan In Balance and to pay for all cost overruns.

 

Construction
or construction: The construction and equipping of the Improvements in accordance with the Plans and Specifications, and all
Tenant Work and related improvements required to be performed by Borrower under Leases and the installation of all personal property,
fixtures and equipment required for the operation of the Project.

 

Construction
Commencement Date: The day that is the thirtieth (30th) day from the date of this Agreement.

 

Construction
Schedule: A schedule reasonably satisfactory to Lender and Lender’s Consultant, establishing a timetable for completion
of the Construction, showing, on a monthly basis, the anticipated progress of the Construction and also showing that the Improvements
can be completed on or before the Completion Date.

 

Contingency
Fund: A Budget Line Item which shall represent an amount necessary to provide reasonable assurances to Lender that additional
funds are available to be used if additional costs and expenses are incurred or additional interest accrues on the Loan, or unanticipated
events or problems occur.

 

Control:
As such term is used with respect to any person or entity, including the correlative meanings of the terms “controlled by”
and “under common control with”, shall mean the possession, directly or indirectly, of the power to direct or cause
the direction of the management policies of such person or entity, whether through the ownership of voting securities, by contract
or otherwise.

 

    	- 3 -

    	 

    

 

Control
Condition: As such term is defined in Section 17.2.

 

Cost
Savings Disbursement: As such term is defined in Section 12.7.

 

Daily
LIBOR Rate: The per annum rate calculated by the Lender in good faith on a daily basis, which Lender determines with reference
to the rate (rounded upwards to the next higher whole multiple of 1/16th if such rate is not such a multiple) based
on the one month London Interbank offered rate for deposits in U.S. Dollars at approximately 11:00 a.m. (London time) on the second
LIBOR Business Day preceding the date of the calculation as determined and adjusted from time to time in Lender's sole discretion.

 

Debt
Service Coverage Ratio: With respect to a particular period, the ratio of (a) the Net Operating Income to (b) the Total Annual
Debt Service.

 

Default
or default: Any event, circumstance or condition, which, if it were to continue uncured, would, with notice or lapse of time
or both, constitute an Event of Default hereunder.

 

Default
Rate: A rate per annum equal to three percentage points (300 basis points) in excess of the Applicable Rate, but shall not
at any time exceed the highest rate permitted by law.

 

Deficiency
Deposit: As such term is defined in Section 11.1.

 

Development
Fee: As such term is defined in Section 15.1(ee).

 

Development
Agreement: That certain Development Agreement dated January 31, 2014, between Borrower and Development Manager.

 

Development
Manager: CDP Developer I, LLC, a Georgia limited liability company.

 

Dispute:
Any controversy, claim or dispute between or among the parties to this Agreement, including any such controversy, claim or dispute
arising out of or relating to (a) this Agreement, (b) any other Loan Document, (c) any related agreements or instruments,
or (d) the transaction contemplated herein or therein (including any claim based on or arising from an alleged personal injury
or business tort).

 

Engineer:
Kimley-Horn Associates, Inc.

 

Environmental
Indemnity: An environmental indemnity from the Borrower and Guarantors, jointly and severally, indemnifying Lender with regard
to all matters related to Hazardous Material and other environmental matters.

 

Environmental
Proceedings: Any proceedings, whether civil (including actions by private parties), criminal, or administrative proceedings,
relating to the presence of Hazardous Material on, within or about the Project.

 

Environmental
Report: An environmental report prepared at Borrower’s expense by a qualified environmental consultant approved by Lender,
dated not more than six (6) months prior to the Loan Opening Date and addressed to Lender (or subject to separate letter agreement
permitting Lender to rely on such environmental report).

 

    	- 4 -

    	 

    

 

ERISA:
The Employee Retirement Income Security Act of 1974, as amended, and the regulations promulgated thereunder from time to time.

 

Event
of Default: As such term is defined in Article 19.

 

Exit
Fee: As such term is defined in Section 7.3.

 

Extension
Option: As such term is defined in Section 4.3.

 

Extension
Term: The twelve (12) month periods of time commencing on the day after the Initial Maturity Date and ending on the First
Extended Maturity Date, and if applicable then ending on the Second Extended Maturity Date.

 

Federal
Funds Effective Rate: Shall mean, for any day, the rate per annum (rounded upward to the nearest one one-hundredth of one
percent (1/100 of 1%)) announced by the Federal Reserve Bank of Cleveland on such day as being the weighted average of the rates
on overnight federal funds transactions arranged by federal funds brokers on the previous trading day, as computed and announced
by such Federal Reserve Bank in substantially the same manner as such Federal Reserve Bank computes and announces the weighted
average it refers to as the “Federal Funds Effective Rate.”

 

FIRREA:
The Financial Institutions Reform, Recovery And Enforcement Act of 1989, as amended from time to time.

 

First
Extended Maturity Date: As such term is defined in Section 4.3.

 

First
Extension Option: As such term is defined in Section 4.3.

 

General
Contract: The general contract dated March 7, 2014, between Borrower and General Contractor, pertaining to the construction
of all onsite and offsite improvements for the Project.

 

General
Contractor:    Summit Contracting Group, Inc.

 

Governmental
Approvals: Collectively, all consents, licenses, and permits and all other authorizations or approvals required from any Governmental
Authority for the Construction in accordance with the Plans and Specifications.

 

Governmental
Authority: Any federal, state, county or municipal government, or political subdivision thereof, any governmental or quasi-governmental
agency, authority, board, bureau, commission, department, instrumentality, or public body, or any court, administrative tribunal,
or public utility.

 

Gross
Revenues: For any period, all revenues of Borrower, determined on a cash basis, derived from the ownership, operation, use,
leasing and occupancy of the Project during such period; provided, however, that in no event shall Gross Revenues
include (i) any loan proceeds; (ii) proceeds or payments under insurance policies (except proceeds of business interruption
insurance); (iii) condemnation proceeds; (iv) any security deposits received from tenants in the Project, unless and until the
same are applied to rent or other obligations in accordance with the tenant’s lease; or (v) any other extraordinary
items, in Lender’s reasonable discretion; provided, however, Gross Revenues shall include, without limitation, late fees,
parking fees, tenant application fees, fees paid in connection with utilities and services provided to tenants and any fees payable
by cable or utility providers to Borrower.

 

    	- 5 -

    	 

    

 

Guarantor:
Alsar Limited Partnership, a Nevada limited partnership, Robert S. Fishel, Mark Mechlowitz, Robert G. Meyer, and Jorge L. Sardinas,
individually or collectively, as the context shall imply.

 

Guarantor
Principal: As such term is defined in Section 17.2.

 

Hazardous
Material: Means and includes gasoline, petroleum, asbestos containing materials, explosives, radioactive materials or any
hazardous or toxic material, substance or waste which is defined by those or similar terms or is regulated as such under any Law
of any Governmental Authority having jurisdiction over the Project or any portion thereof or its use, including: (i) any
“hazardous substance” defined as such in (or for purposes of) the Comprehensive Environmental Response, Compensation
and Liability Act, 42 U.S.C.A. § 9601(14) as may be amended from time to time, or any so-called “superfund”
or “superlien” Law, including the judicial interpretation thereof; (ii) any “pollutant or contaminant”
as defined in 42 U.S.C.A. § 9601(33); (iii) any material now defined as “hazardous waste” pursuant
to 40 C.F.R. Part 260; (iv) any petroleum, including crude oil or any fraction thereof; (v) natural gas, natural
gas liquids, liquefied natural gas, or synthetic gas usable for fuel; (vi) any “hazardous chemical” as defined
pursuant to 29 C.F.R. Part 1910; and (vii) any other toxic substance or contaminant that is subject to any other Law
or other past or present requirement of any Governmental Authority. Any reference above to a Law, includes the same as it may
be amended from time to time, including the judicial interpretation thereof. "Hazardous Material" shall not include
commercially reasonable amounts of such materials used in the ordinary course of Construction and maintenance and operation of
the Project which are used and stored in accordance with all applicable Laws pertaining to Hazardous Material.

 

Improvements:
The improvements referred to in Recital A hereto and more particularly described in the Plans and Specifications, and offsite
improvements and together with any existing improvements located on the Land not to be demolished.

 

In
Balance or in balance: As such term is defined in Article 11.

 

Including
or including: Including but not limited to.

 

Initial
Maturity Date: May 14, 2017.

 

Interest
Rate Agreement: An Interest Rate Protection Product purchased by Borrower from Lender.

 

Interest
Rate Protection Product: An interest rate hedging product, such as a cap or swap. 

 

Internal
Revenue Code: The Internal Revenue Code of 1986, as amended from time to time.

 

Land:
As such term is defined in Recital A.

 

Laws:
Collectively, all federal, state and local laws, statutes, codes, ordinances, orders, rules and regulations, including judicial
opinions or precedential authority in the applicable jurisdiction.

 

Late
Charge: As such term is defined in Section 4.6.

 

Leases:
The collective reference to all leases, subleases and occupancy agreements affecting the Project or any part thereof now existing
or hereafter executed and all amendments, modifications or supplements thereto approved in writing by Lender.

 

    	- 6 -

    	 

    

 

Lender:
As defined in the opening paragraph of this Agreement, and including any successor holder of the Loan from time to time.

 

Lender’s
Consultant: An independent consulting architect, inspector, and/or engineer designated by Lender in Lender’s sole discretion.

 

LIBOR
Business Day: A Business Day on which dealings in U.S. dollars are carried on in the London Interbank Market.

 

LIBOR
Rate: For any LIBOR Rate Interest Period, the average rate (rounded upwards to the nearest 1/16th) as shown by Reuters at
which deposits in U.S. dollars are offered by first class banks in the London Interbank Market at approximately 11:00 a.m. (London
time) on the day that is two (2) LIBOR Business Days prior to the first day of such LIBOR Rate Interest Period with a maturity
approximately equal to such LIBOR Rate Interest Period and in an amount approximately equal to the amount to which such LIBOR
Rate Interest Period relates, adjusted for reserves and taxes if required by applicable regulations. If Reuters no longer reports
such rate or Lender determines in good faith that the rate so reported no longer accurately reflects the rate available to Lender
in the London Interbank Market, Lender may select a replacement index.

 

LIBOR
Rate Interest Period: With respect to each amount bearing interest at a LIBOR based rate, a period of one month or daily,
to the extent deposits with such maturities are available to Lender, provided, however, that any LIBOR Rate Interest Period which
would end after the Maturity Date shall end on the Maturity Date.

 

LIBOR
Rate Margin:  two and fifteen one-hundredths percent ( 215 basis points) per annum.

 

LIBOR
Rate Option: As defined in Section 5.1(b).

 

Loan:
As defined in Recital B.

 

Loan
Amount: The maximum amount of the Loan as set forth in Section 4.1(a) as reduced by principal payments made from time
to time.

 

Loan
Documents: The collective reference to this Agreement, the documents and instruments listed in Section 4.2, and all the other
documents and instruments entered into from time to time, evidencing or securing the Loan or any obligation of payment thereof
or performance of Borrower’s or Guarantor’s obligations in connection with the transaction contemplated hereunder
and any Interest Rate Agreement, each as amended.

 

Loan
Opening Date: The date of the first disbursement of proceeds of the Loan.

 

Major
Subcontractor: Any subcontractor under a Major Subcontract.

 

Major
Subcontracts: All subcontracts between the General Contractor and any subcontractors and material suppliers which provide
for an aggregate contract price equal to or greater than Seven Hundred Fifty Thousand and No/100th Dollars ($750,000.00).
Borrower and Lender acknowledge that because the General Contract does not provide for such approval rights, neither Borrower
nor Lender shall have any right to approve with respect to the General Contract any Major Subcontractors or other subcontractor
or Major Subcontracts or other subcontracts.

 

Material
Adverse Change or material adverse change: If, in Lender’s reasonable discretion, the business prospects, operations
or financial condition of a person, entity or property has changed in a manner which could impair in any material respect the
value of Lender’s security for the Loan, prevent timely repayment of the Loan or otherwise prevent the applicable person
or entity from timely performing any of its material obligations under the Loan Documents.

 

    	- 7 -

    	 

    

 

Maturity
Date: The Initial Maturity Date, provided, if Borrower timely satisfies the conditions to extend the term of the Loan pursuant
to Section 4.3(b) and Section 4.3(c), then the Maturity Date shall be extended to the First Extended Maturity Date
and if applicable, the Second Extended Maturity Date.

 

Monthly
Excess Cash Flow: For any month, the amount by which Gross Revenues exceed the sum of (a) actual Operating Expenses and (b)
actual debt service on the Loan.

 

Mortgage:
A mortgage (or deed of trust), assignment of leases and rents, security agreement and fixture filing, executed by Borrower for
the benefit of Lender securing this Agreement, the Note, and all obligations of Borrower in connection with the Loan, granting
a first priority lien on Borrower’s fee interest in the Project, subject only to the Permitted Exceptions.

 

Net
Operating Income: (a) (i) The annualized gross rental revenue from the Project derived from arm's length, market rate rents
from Leases with unaffiliated third parties, plus (ii) other revenue derived from the operation of the Project, including service
fees or charges, but excluding capital gains income derived from the sale of assets and other items of income or revenue which
the Lender reasonably determines are unlikely to occur in any subsequent period, all for the 3- month period ending on the date
of calculation, plus (iii) any income that does not fall into the categories above but which is otherwise Gross Revenues, less
(b) the greater of (i) actual operating expenses including, but not limited to, cleaning, utilities, administrative, landscaping,
security and management expenses, repair and maintenance expenses, a $200.00 per unit reserve for replacements, a five percent
(5%) vacancy factor for any period during which more than ninety-five percent (95%) of the net rentable area of the Project is
leased and occupied, a management fee equal to the greater of (x) three and fifty one-hundredths percent (3.50%) of Gross Revenues
of the Project and (y) the management fee actually paid under any management agreement, and fixed expenses (such as insurance,
real estate and other taxes), all for the 12-month period ending on the date of calculation, but excludes therefrom all expenses
of a non-recurring, extraordinary nature and capital expenditures (and any depreciation or amortization thereof) and similar non-cash
items, and (ii) the pro forma annual operating expenses of the Project, that is, the total number of units in the Project (i.e.
296) times $6,143.00). All operating expenses shall be related to the Project, shall be for services from arm's length third party
transactions or equivalent to the same, and shall exclude all expenses for capital improvements and replacements, income taxes,
principal and interest on the Loan and depreciation or amortization of capital expenditures and other similar non-cash items.

 

Note:
A promissory note, in the Loan Amount, executed by Borrower and payable to the order of Lender, evidencing the Loan.

 

OFAC
Compliance Condition: As such term is defined in Section 17.2.

 

Opening
of the Loan or Loan Opening: The first disbursement of Loan proceeds in excess of the $1,000.00 disbursement made on the date
of this Agreement.

 

Operating
Account: A deposit account opened and maintained by Borrower with Lender, to be utilized in the manner set forth in Section
4.1(e).

 

Operating
Expenses: For any period, the actual costs and expenses of owning, operating, managing and maintaining the Project during
such period incurred by Borrower, determined on a cash basis (except for real and personal property taxes and insurance premiums,
which shall be determined on an accrual basis) (including, a $200.00 per unit annual reserve, a five percent (5%) vacancy factor
for any period during which more than ninety-five percent (95%) of the net rentable area of the Project is leased and occupied,
and a management fee equal to the greater of (x) three and fifty one-hundredths percent (3.50%) of Gross Revenues of the Project
and (y) the management fee actually paid under any management agreement). All operating expenses shall be related to the Project,
shall be for services from arm's length third party transactions or equivalent to the same, and shall exclude all expenses for
capital improvements and replacements, income taxes, principal and interest on the Loan and depreciation or amortization of capital
expenditures and other similar non-cash items.

 

    	- 8 -

    	 

    

 

Payment
Guaranty: A guaranty of payment executed by each Guarantor and pursuant to which the Guarantors jointly and severally guarantee
payment of principal, interest and other amounts due under the Loan Documents, subject to certain limitations as described therein
on maximum liability.

 

Permitted
Exceptions: Those matters listed on Schedule B to the Title Policy to which title to the Project may be subject at the Loan
Opening and thereafter such other title exceptions as Lender may reasonably approve in writing (including the liens established
under the Loan Documents).

 

Plans
and Specifications: Detailed plans and specifications for the Improvements, as reasonably approved by Lender pursuant to Section
9.1(f), as modified hereafter with Lender’s reasonable prior written approval or as otherwise expressly permitted by
this Agreement.

 

Prime
Rate:  That interest rate established from time to time by Lender as Lender's prime rate, whether or not such rate is publicly
announced; the Prime Rate may not be the lowest interest rate charged by Lender for commercial or other extensions of credit;

 

Prime
Rate Margin: 1% (100 basis points) per annum.

 

Pro-Forma
Projection: A pro forma statement of projected income and expenses of Project.

 

Project:
The collective reference to (i) the Land, together with all buildings, structures and improvements located or to be located
thereon, including the Improvements, (ii) all rights, privileges, easements and hereditaments relating or appertaining thereto,
and (iii) all personal property, fixtures and equipment required or beneficial for the operation thereof.

 

Required
Permits: Each building permit, environmental permit, utility permit, land use permit, wetland permit and any other permits,
approvals or licenses issued by any Governmental Authority which are required in connection with the Construction or operation
of the Project.

 

Reserve
Percentage: For any LIBOR Rate Interest Period, that percentage which is specified three (3) Business Days before the first
day of such LIBOR Rate Interest Period by the Board of Governors of the Federal Reserve System (or any successor) or any other
governmental or quasi-governmental authority with jurisdiction over Lender for determining the maximum reserve requirement (including,
but not limited to, any marginal reserve requirement) for Lender with respect to liabilities consisting of or including (among
other liabilities) Eurocurrency liabilities in an amount equal to that portion of the Loan affected by such LIBOR Rate Interest
Period and with a maturity equal to such LIBOR Rate Interest Period.

 

Second
Extended Maturity Date: As such term is defined in Section 4.3.

 

Second
Extension Option: As such term is defined in Section 4.3.

 

Soil
Report: A soil test report prepared by a licensed engineer reasonably satisfactory to Lender indicating to the satisfaction
of Lender that the soil and subsurface conditions underlying the Project will support the Improvements.

 

State:
The state in which the Land is located.

 

    	- 9 -

    	 

    

 

Substitute
Guarantor: As such term is defined in Article 19.

 

Subcontracts:
Subcontracts between the General Contractor and third parties for labor or materials to be furnished to the Project by Major Subcontractors.

 

Tenant:
The tenant under a Lease.

 

TIC
Agreement: That certain Tenancy In Common Agreement dated January 31, 2014, between and among the TIC Interest Holders, as
amended and supplemented by that certain TIC Management Agreement dated January 31, 2014, between and among the TIC Interest Holders.

 

TIC
Interest Holders: Eldorado, LLC, an Ohio limited liability company, Spyglass Hill, LLC, an Ohio limited liability company,
and BR/CDP UCFP Venture, LLC, a Delaware limited liability company.

 

Title
Insurer: First American Title Insurance Company, or such other title insurance company licensed in the State as may be approved
in writing by Lender.

 

Title
Policy: An ALTA Mortgagee’s Loan Title Insurance Policy with extended coverage issued by the Title Insurer insuring
the lien of the Mortgage as a valid first, prior and paramount lien upon the Project and all appurtenant easements, and subject
to no other exceptions other than the Permitted Exceptions and otherwise satisfying the requirements of Exhibit C attached
hereto and made a part hereof.

 

Total
Annual Debt Service: The aggregate of debt service payments comprising principal and interest for a twelve (12) month
period on the stated principal amount of the Loan, assuming (a) a fixed per annum interest rate equal to the Assumed Interest
Rate determined as of the date of calculation; and (b) monthly payments of principal and interest based on an amortization period
of thirty (30) years.

 

Transfer:
Any sale, transfer, lease (other than a Lease approved by Lender), conveyance, alienation, pledge, assignment, mortgage, encumbrance
hypothecation or other disposition of (a) all or any portion of the Project or any portion of any other security for the Loan,
(b) all or any portion of the Borrower’s right, title and interest (legal or equitable) in and to the Project or any portion
of any other security for the Loan, or (c) any interest in Borrower or any interest in any entity which directly or indirectly
holds an interest in, or directly or indirectly controls, Borrower.

 

Trust
Agreement: That certain BR/CDP Colonial Trust Agreement dated December 15, 2013, between and among the TIC Interest Holders.

 

Unavoidable
Delay: Any delay in the construction of the Project, caused by natural disaster, fire, earthquake, floods, explosion, hurricanes,
extraordinary adverse weather conditions, inability to procure or a general shortage of labor, equipment, facilities, energy,
materials or supplies in the open market, failure of transportation, strikes or lockouts, acts of God, war, riots, building moratoriums,
delays caused by governmental authority and financial market failure, for which Borrower has notified Lender in writing.

 

Venture
Agreement: Operating Agreement of BR/CDP UCFP Venture, LLC dated January 15, 2014, between BR Member and Catalyst Member.
The Venture Agreement shall not be amended in any material respect without Lender’s
consent, not to be unreasonably withheld.

 

Venture
Control Transfer: As such term is defined in Section 17.2.

 

    	- 10 -

    	 

    

 

2.2           Other
Definitional Provisions.

 

All
terms defined in this Agreement shall have the same meanings when used in the Note, Mortgage, any other Loan Documents, or any
certificate or other document made or delivered pursuant hereto. The words “hereof”, “herein” and “hereunder”
and words of similar import when used in this Agreement shall refer to this Agreement.

 

ARTICLE
3

BORROWER’S REPRESENTATIONS AND WARRANTIES

 

3.1           Representations
and Warranties.

 

To
induce Lender to execute this Agreement and perform its obligations hereunder, Borrower hereby represents and warrants to Lender
as follows:

 

(a)          Borrower
has good and marketable fee simple title to the Project, subject only to the Permitted Exceptions.

 

(b)          Except
as previously disclosed to Lender in writing, no litigation or proceedings are pending, or to the best of Borrower’s knowledge
threatened (in writing), against Borrower or any Guarantor, which could, if adversely determined, cause a Material Adverse Change
with respect to Borrower, any Guarantor or the Project. There are no pending Environmental Proceedings and Borrower has no knowledge
of any threatened Environmental Proceedings or any facts or circumstances which may give rise to any future Environmental Proceedings.

 

(c)          Borrower
is a duly organized and validly existing Delaware limited liability company and has full power and authority to execute, deliver
and perform all Loan Documents to which Borrower is a party, and such execution, delivery and performance have been duly authorized
by all requisite action on the part of Borrower. 

 

(d)          No
consent, approval or authorization of or declaration, registration or filing with any Governmental Authority or nongovernmental
person or entity, including any creditor, partner, or member of Borrower or any Guarantor, is required in connection with the
execution, delivery and performance of this Agreement or any of the Loan Documents other than the recordation of the Mortgage,
Assignment of Leases and Rents and the filing of UCC-1 Financing Statements, except for such consents, approvals or authorizations
of or declarations or filings with any Governmental Authority or non-governmental person or entity where the failure to so obtain
would not have a material adverse effect on Borrower or such Guarantor or which have been obtained as of any date on which this
representation is made or remade.

 

(e)          The
execution, delivery and performance of this Agreement, the execution and payment of the Note and the granting of the Mortgage
and other security interests under the other Loan Documents have not constituted and will not constitute, upon the giving of notice
or lapse of time or both, a breach or default under any other agreement to which Borrower or Guarantor is a party or may be bound
or affected, or a violation of any law or court order which may adversely affect the Project, any part thereof, any interest therein,
or the use thereof.

 

(f)          There
is no default under this Agreement or any of the other Loan Documents, nor to Borrower’s knowledge, any condition which,
after notice or the passage of time or both, would constitute a default or an Event of Default under this Agreement or any of
the other Loan Documents.

 

(g)          (i)
No condemnation of any portion of the Project; (ii) no condemnation or relocation of any roadways abutting the Project; and
(iii) no proceeding to deny access to the Project from any point or planned point of access to the Project, has commenced
or, to the best of Borrower’s knowledge, is contemplated by any Governmental Authority.

 

    	- 11 -

    	 

    

 

(h)          The
amounts set forth in the Budget, after taking into account reallocated cost savings approved by Lender in accordance with Section
10.2 of this Agreement and change orders expressly permitted under Section 15.1(c) or otherwise approved in writing by Lender,
present a full and complete itemization by category of all costs, expenses and fees which Borrower reasonably expects to pay or
reasonably anticipates becoming obligated to pay to complete the Construction and operate the Project (until the Project achieves
breakeven operations). Borrower is unaware of any other such costs, expenses or fees which are material and are not included in
the Budget.

 

(i)           Neither
the construction of the Improvements nor the use of the Project when completed and the contemplated accessory uses will violate
(i) any Laws (including subdivision, zoning, building, environmental protection and wetland protection Laws); or (ii) any
building permits, restrictions of record, or agreements affecting the Project or any part thereof. Neither the zoning authorizations,
approvals or variances nor any other right to construct or to use the Project is to any extent dependent upon or related to any
real estate other than the Land. All Government Approvals required for the Construction in accordance with the Plans and Specifications
have been obtained or will be capable of being obtained following the Loan Opening, and all Laws relating to the Construction
and operation of the Improvements have been complied with and all permits and licenses required for the operation of the Project
which cannot be obtained until the Construction is completed can be obtained if the Improvements are completed in accordance with
the Plans and Specifications.

 

(j)           Upon
completion of the Construction, the Project will have adequate (i.e. to operate the Project for its intended use) water, gas and
electrical supply, storm and sanitary sewerage facilities, means of access between the Project and public rights-of-way; none
of the foregoing will be foreseeably delayed or impeded by virtue of any requirements under any applicable Laws.

 

(k)          No
brokerage fees or commissions are payable by or to any person in connection with this Agreement or the Loan to be disbursed hereunder,
other than a brokerage fee payable to Jones Lang LaSalle, which fee will be paid in conjunction with the closing of this Loan.

 

(l)           To
Borrower’s knowledge, all financial statements and other written material information previously furnished by Borrower or
any Guarantor to Lender in connection with the Loan are, in all material respects, true, complete and correct in all material
respects and fairly present the financial conditions of the subjects thereof as of the respective dates thereof and do not fail
to state any material fact necessary to make such statements or information not misleading, and no Material Adverse Change with
respect to Borrower or any Guarantor has occurred since the respective dates of such statements and information, unless disclosed
to Lender in writing. Neither Borrower nor any Guarantor has any material liability, contingent or otherwise, not disclosed in
such financial statements.

 

(m)          Except
as disclosed by Borrower to Lender, including, without limitation, as set forth in the Environmental Report, to Borrower’s
knowledge: (i) the Project is, except for materials used in the ordinary course of construction, maintenance and operation of
the Project, free of all Hazardous Material and is in compliance with all applicable Laws; (ii) neither Borrower nor, to the best
knowledge of Borrower, any other person or entity, has ever caused or permitted any Hazardous Material to be placed, held, located
or disposed of on, under, at or in a manner to affect the Project, or any part thereof, and the Project has never been used (whether
by Borrower or, to the best knowledge of Borrower, by any other person or entity) for any activities involving, directly or indirectly,
the use, generation, treatment, storage, transportation, or disposal of any Hazardous Material; (iii) neither the Project nor
Borrower is subject to any existing, pending, or, to the best of Borrower’s knowledge, threatened (in writing) investigation
or inquiry by any Governmental Authority, and the Project is not subject to any remedial obligations under any applicable Laws
pertaining to health or the environment; and (iv) there are no underground tanks, vessels, or similar facilities for the storage,
containment or accumulation of Hazardous Materials of any sort on, under or affecting the Project.

 

    	- 12 -

    	 

    

 

(n)          The
Project is taxed separately without regard to any other property and for all purposes the Project may be mortgaged, conveyed and
otherwise dealt with as an independent parcel.

 

(o)          Borrower
and its agents have not entered into any Leases, subleases or other arrangements for occupancy of space within the Project, except
for the Permitted Exceptions.

 

(p)          When
the Construction is completed in accordance with the Plans and Specifications, no building or other improvement will encroach
upon any property line, building line, setback line, side yard line or any recorded or visible easement with respect to the Project.

 

(q)          The
Loan is not being made for the purpose of purchasing or carrying “margin stock” within the meaning of Regulation G,
T, U or X issued by the Board of Governors of the Federal Reserve System, and Borrower agrees to execute all instruments necessary
to comply with all the requirements of Regulation U of the Federal Reserve System.

 

(r)           Borrower
is not a party in interest to any plan defined or regulated under ERISA, and the assets of Borrower are not “plan assets”
of any employee benefit plan covered by ERISA or Section 4975 of the Internal Revenue Code.

 

(s)           Borrower
is not a “foreign person” within the meaning of Section 1445 or 7701 of the Internal Revenue Code.

 

(t)           Borrower
uses no trade name other than its actual name set forth herein. The principal place of business of Borrower is as stated in Article
22.

 

(u)          UCFP
Owner, LLC’s place of formation or organization is the State of Delaware.

 

(v)          All
statements set forth in the Recitals are true and correct.

 

(w)          Neither
Borrower nor any Guarantor is (or will be) a person with whom Lender is restricted from doing business under regulations of the
Office of Foreign Asset Control (“OFAC”) of the Department of the Treasury of the United States of America (including,
those Persons named on OFAC’s Specially Designated and Blocked Persons list) or under any statute, executive order (including,
the September 24, 2001 Executive Order Blocking Property and Prohibiting Transactions With Persons Who Commit, Threaten to Commit,
or Support Terrorism), or other governmental action and is not and shall not engage in any dealings or transactions or otherwise
be associated with such persons. In addition, Borrower hereby agrees to provide to the Lender with any additional information
that the Lender deems reasonably necessary from time to time in order to ensure compliance with all applicable Laws concerning
money laundering and similar activities.

 

(x)
(i) Borrower is the trustee under the Trust Agreement; (ii) true, correct and complete copies of the Trust Agreement and TIC Agreement
have been delivered to Lender; (iii) the Trust Agreement and TIC Agreement are in full force and effect and have not been modified,
supplemented or amended in any way; (iv) there are no defaults by any party under the Trust Agreement or the TIC Agreement, nor
any event, circumstance or condition thereunder, which, if it were to continue uncured, would, with notice or lapse of time or
both, constitute a default thereunder; and (v) under the Trust Agreement and the TIC Agreement, Borrower has full power and authority
to execute, deliver and perform all Loan Documents to which Borrower is a party, and TIC Interest Holders have approved the Loan
and authorized Borrower to enter into and perform this Agreement, the Mortgage and the other Loan Documents.

 

    	- 13 -

    	 

    

 

(y)          Both
Borrower and the Project are in full compliance with the terms and conditions of the Permitted Exceptions; all Permitted Exceptions
are in full force and effect; there is no default existing under any Permitted Exceptions by Borrower or, to Borrower’s
knowledge, by any other parties thereto; all obligations of Borrower under the Permitted Exceptions required to be performed as
of the date of this Loan Agreement have been performed; all amounts due under any Permitted Exceptions have been paid in full
and no amounts are due or owing by Borrower with respect to the Project or, to Borrower’s knowledge with respect to any
other party to any of the Permitted Exceptions; and none of the Permitted Exceptions have been amended in any instrument or by
other means, which amendment has not been provided to Lender.

 

(z)           There
are no amounts due and owing to any Governmental Authority by Borrower or, to Borrower’s knowledge, by other parties under
the Permitted Exceptions which have not been paid.

 

3.2           Survival
of Representations and Warranties.

 

Borrower
agrees that all of the representations and warranties set forth in Section 3.1 and elsewhere in this Agreement are true
as of the date hereof, will be true at the Loan Opening and, except for matters which have been disclosed by Borrower and approved
by Lender in writing (which approval shall not be unreasonably withheld), at all times thereafter. Each request for a disbursement
under the Loan Documents shall constitute a reaffirmation of such representations and warranties, as deemed modified in accordance
with the disclosures made and approved as aforesaid, as of the date of such request. It shall be a condition precedent to the
Loan Opening and each subsequent disbursement that each of said representations and warranties is true and correct as of the date
of such requested disbursement. Each disbursement of Loan proceeds shall be deemed to be a reaffirmation by Borrower that each
of the representations and warranties is true and correct as of the date of such disbursement. In addition, at Lender’s
request, Borrower shall reaffirm such representations and warranties in writing prior to each disbursement hereunder.

 

ARTICLE
4

LOAN AND LOAN DOCUMENTS

 

4.1           Agreement
to Borrow and Lend; Lender’s Obligation to Disburse.

 

Subject
to the terms, provisions and conditions of this Agreement and the other Loan Documents, Borrower agrees to borrow from Lender
and Lender agrees to lend to Borrower the Loan, for the purposes and subject to all of the terms, provisions and conditions contained
in this Agreement.

 

(a)          The
principal amount of the Loan shall not exceed the least of (i) Twenty-Seven Million Five Hundred Thousand and No/100 Dollars ($27,500,000.00),
(ii) 75% of the approved development and lease-up costs of the Project, as set out in the Budget, (iii) 75% of the appraised value
of the Project “upon stabilization,” as set forth in the appraisal of the Project approved by the Lender, and (iv)
such amount as will result in a Debt Service Coverage Ratio of not less than 1.23 to 1.00 (based, for purposes of this calculation,
on the stabilized income and expenses of the Project projected in the appraisal of the Project approved by the Lender).

 

(b)          Lender
agrees, upon Borrower’s compliance with and satisfaction of all conditions precedent to the Loan Opening and provided the
Loan is In Balance, no Material Adverse Change has occurred with respect to Borrower, any Guarantor, or the Project and no material
default or Event of Default has occurred and is continuing hereunder, to Open the Loan to reimburse Borrower for a portion of
the costs incurred by Borrower in connection with the development of the Project and the construction of the Improvements, to
the extent provided for in the Budget.

 

    	- 14 -

    	 

    

 

(c)          After
the Opening of the Loan, Borrower shall be entitled to receive further successive disbursements of the proceeds of the Loan in
accordance with Articles 9, 12 and 13 within ten (10) Business Days after compliance with all conditions
precedent thereto, provided that (i) the Loan remains In Balance; (ii) Borrower has complied with all conditions precedent to
disbursement from time to time including the requirements of Section 3.2 and Articles 8, 9, 12 and 13; (iii)
no Material Adverse Change has occurred with respect to Borrower, any Guarantor or the Project and (iv) no Event of Default and
no material default exists hereunder or under any other Loan Document.

 

(d)          To
the extent that Lender may have acquiesced in noncompliance with any requirements precedent to the Opening of the Loan or precedent
to any subsequent disbursement of Loan proceeds, such acquiescence shall not constitute a waiver by Lender, and Lender may at
any time after such acquiescence require Borrower to comply with all such requirements.

 

(e)          Borrower
shall, prior to the Opening of the Loan, open an Operating Account. Borrower authorizes Lender to disburse the Loan proceeds by
crediting the Operating Account; provided, however, that Lender shall not be obligated to use such method. Upon
the occurrence and during the continuance of an Event of Default, without in any way limiting any other rights and remedies that
Lender may have under this Agreement or the other Loan Documents with respect to the Operating Account or otherwise, Lender is
authorized to pay any principal or interest due upon the Note when and as same shall become due by debiting funds on deposit in
the Operating Account. For the avoidance of doubt, except upon the occurrence and during the continuance of an Event of Default,
Lender shall disburse Loan proceeds into the Operating Account for Borrower to pay General Contractor and Lender shall not pay
General Contractor directly for Construction.

 

4.2           Loan
Documents.

 

Borrower
agrees that it will, on or before the Loan Opening Date, execute and deliver or cause to be executed and delivered to Lender the
following documents in form and substance acceptable to Lender:

 

(a)          The
Note.

 

(b)          The
Mortgage.

 

(c)          The
Assignment of Rents.

 

(d)          The
Completion Guaranty.

 

(f)          The
Payment Guaranty.

 

(g)          The
Environmental Indemnity.

 

(h)          A
collateral assignment of construction documents, including, without limitation, the General Contract, all architecture and engineering
contracts, Plans and Specifications, permits, licenses, approvals and development rights, together with consents to the assignment
and continuation agreements from the General Contractor, the architect and other parties reasonably specified by Lender.

 

(i)           Such
UCC financing statements as Lender determines are advisable or necessary to perfect or notify third parties of the security interests
intended to be created by the Loan Documents.

 

(j)           Such
other documents, instruments or certificates as Lender and its counsel may reasonably require, including such documents as Lender
in its sole discretion deems necessary or appropriate to effectuate the terms and conditions of this Agreement and the Loan Documents,
and to comply with the laws of the State.

 

    	- 15 -

    	 

    

 

4.3           Term
of the Loan.

 

(a)          All
principal, interest and other sums due under the Loan Documents shall be due and payable in full on the Maturity Date. All references
herein to the Maturity Date shall mean Initial Maturity Date, provided that Borrower shall have the right to: (i) subject to the
terms of Section 4.3(b), extend the Maturity Date for an additional twelve (12) month term (the “First Extension
Option”), thereby, extending the Maturity Date to the twelve (12) month anniversary of the Initial Maturity Date (the “First
Extended Maturity Date”); and (ii) subject to the terms of Section 4.3(b), extend the Maturity Date for a second
additional twelve (12) month term (the “Second Extension Option”), thereby, extending the Maturity Date to the twelve
(12) month anniversary of the First Extended Maturity Date (the “Second Extended Maturity Date”). The First Extension
Option and Second Extension Option are collectively known as an “Extension Option”.

 

(b)          Borrower
may only exercise the First Extension Option upon satisfying the following conditions:

 

(i)          Borrower
shall have delivered to Lender written notice of its election to exercise the First Extension Option no earlier than ninety (90)
days and no later than thirty (30) days prior to the Initial Maturity Date;

 

(ii)         Lender
shall have received Borrower's and Guarantor's current financial statements, certified as correct by Borrower and Guarantor, UCFP
Owner, LLC shall be in good standing and there shall have been no material adverse change in Borrower's or Guarantor's financial
condition;

 

(iii)        Construction
of the Improvements has been completed in accordance with all requirements of this Agreement;

 

(iv)        The
notice given pursuant to clause (i) shall be accompanied by payment of an extension fee in the amount of fifteen basis points
(0.15%) of the Loan Amount;

 

(v)         No
Event of Default exists under the Loan Documents, and no event exists which would be an Event of Default following notice and/or
if not cured within the time allowed; and

 

(vi)        Lender
determines, based on Borrower’s written affidavit and such supporting data and other evidence as the Lender may reasonably
require, that the Debt Service Coverage Ratio is not less than 1.20:1.00. In the event this Debt Service Coverage Ratio is not
met, Borrower may satisfy this Debt Service Coverage Ratio prior to the Initial Maturity Date by making a voluntary paydown of
the Loan, together with a mutually agreed-upon reduction to the committed amount of the Loan, so that the Loan Amount and maximum
committed amount of the Loan, after giving effect to such paydown and reduction, does not exceed the amount which results in a
Debt Service Coverage Ratio of 1.20:1.00 (based, for purposes of this calculation, on the annualized amounts of Net Operating
Income and Total Annual Debt Service for the Project for the 3-month period ending on the April 30th immediately preceding
the Initial Maturity Date). In connection with Borrower’s notice of its election to exercise the First Extension Option,
Borrower will submit or cause to be submitted to Lender all documentation evidencing satisfaction of the above required Debt Service
Coverage Ratio together with an affidavit from an officer of Borrower, in a form satisfactory to Lender, affirming that the Debt
Service Coverage Ratio is equal to or greater than 1.20:1.00.

 

(c)           Borrower
may only exercise the Second Extension Option upon satisfying the following conditions:

 

    	- 16 -

    	 

    

 

(i)          Borrower
shall have delivered to Lender written notice of such election no earlier than ninety (90) days and no later than thirty (30)
days prior to the First Extended Maturity Date;

 

(ii)         Lender
shall have received Borrower's and Guarantor's current financial statements, certified as correct by Borrower and Guarantor, Borrower
shall be in good standing and there shall have been no material adverse change in Borrower's or Guarantor's financial condition;

 

(iii)        Construction
of the Improvements has been completed in accordance with all requirements of this Loan Agreement;

 

(iv)         Such
notice is accompanied by an extension fee in the amount of fifteen basis points (0.15%) of the Loan Amount;

 

(v)          No
Event of Default exists under the Loan Documents, and no even exists which would be an Event of Default following notice and/or
if not cured within the time allowed; and

 

(vi)         Lender
determines, based on Borrower’s written affidavit and such supporting data and other evidence as the Lender may require,
that the Debt Service Coverage Ratio is not less than 1.25:1.00. In the event this Debt Service Coverage Ratio is not met, Borrower
may satisfy this Debt Service Coverage Ratio prior to the First Extended Maturity Date by making a voluntary paydown of the Loan,
together with a mutually agreed-upon reduction to the committed amount of the Loan, so that the Loan Amount and maximum committed
amount of the Loan, after giving effect to such paydown and reduction, does not exceed the amount which results in a Debt Service
Coverage Ratio of 1.25:1.00 (based, for purposes of this calculation, on the annualized amounts of Net Operating Income and Total
Annual Debt Service for the Project for the 3-month period ending on the April 30th immediately preceding the First
Extended Maturity Date). In connection with Borrower’s notice of its election to exercise the Second Extension Option, Borrower
will submit or cause to be submitted to Lender all documentation evidencing satisfaction of the above required Debt Service Coverage
Ratio together with an affidavit from an officer of Borrower, in a form satisfactory to Lender, affirming that the Debt Service
Coverage Ratio is equal to or greater than 1.25:1.00.

 

4.4           Prepayments.

 

Borrower
shall have the right to make prepayments of the Loan, in whole or in part, without prepayment penalty, upon not less than seven
(7) days’ prior written notice to Lender. No prepayment of all or part of the Loan shall be permitted unless same is made
together with the payment of all interest accrued on the Loan through the date of prepayment and an amount equal to all Breakage
Costs and attorneys’ fees and disbursements incurred by Lender as a result of the prepayment.

 

4.5.          Required
Principal Payments.

 

All
principal shall be paid on or before the Maturity Date. If the Maturity Date is extended pursuant to Section 4.3 above, then commencing
on the tenth (10th) day of the first calendar month following the Initial Maturity Date and continuing on the tenth (10th) day
of each succeeding calendar month thereafter through and including the tenth (10th) day of the calendar month in which the Maturity
Date occurs, Borrower shall make monthly payments of principal and interest in an amount equal to the outstanding principal balance
of the Loan as of the Initial Maturity Date, with the principal component of such monthly payment amount determined based on an
amortization period of thirty (30) years and the Assumed Interest Rate. The manner in which each payment shall be applied to principal
and interest shall be determined by Lender at the time Borrower extends the Maturity Date pursuant to Section 4.3 above. For avoidance
of doubt, prior to the Initial Maturity Date, scheduled monthly payments shall consist of interest only payments at the Applicable
Rate (unless the Default Rate is applicable) on the outstanding principal balance of the Loan.

 

    	- 17 -

    	 

    

 

4.6.          Late
Charge.

 

Any
and all amounts due hereunder or under the other Loan Documents which remain unpaid more than five (5) days after the date said
amount was due and payable shall incur a fee (the “Late Charge” of four percent (4%) of said amount, which payment
shall be in addition to all of Lender’s other rights and remedies under the Loan Documents, provided that no Late Charge
shall apply to the final payment of principal on the Maturity Date.

 

ARTICLE
5

INTEREST

 

5.1           Interest
Rate.

 

(a)          The
Loan will bear interest at the Applicable Rate, unless the Default Rate is applicable. The Adjusted Daily LIBOR Rate shall be
the “Applicable Rate”, except that the Adjusted One Month LIBOR Rate shall be the “Applicable Rate” with
respect to portions of the Loan as to which a LIBOR Rate Option is then in effect. For each disbursement of proceeds of the loan,
Borrower shall deliver to Lender irrevocable notice (which may be (i) verbal notice provided that Borrower delivers to Lender
facsimile confirmation within twenty four (24) hours of such verbal notice or (ii) electronic mail notice within twenty four (24)
hours of such verbal notice) of the requested amount of such disbursement, not later than 11:00 a.m. Cleveland time on the third
LIBOR Business Day prior to the desired date of disbursement. Borrower shall pay interest in arrears on the tenth (10th)
day of every calendar month in the amount of all interest accrued and unpaid. The first payment of interest on the Loan shall
be due on June 10, 2014. All payments (whether of principal or of interest) shall be deemed credited to Borrower’s account
only if received by 1:00 p.m. Cleveland time on a Business Day; otherwise, such payment shall be deemed received on the next Business
Day.

 

(b)          Provided
that no Event of Default exists, Borrower shall have the option (the “LIBOR Rate Option”) to elect from time to time
in the manner and subject to the conditions hereinafter set forth the Adjusted One Month LIBOR Rate as the Applicable Rate for
all or any portion of the Loan which would otherwise bear interest at the Adjusted Daily LIBOR Rate.

 

(c)          The
only manner in which Borrower may exercise the LIBOR Rate Option is by giving Lender irrevocable written notice in the form of
Exhibit K attached hereto not later than 11:00 a.m. Cleveland time on the second LIBOR Business Day prior to the proposed
commencement of the relevant LIBOR Rate Interest Period, which written notice shall specify: (i) the portion of the Loan with
respect to which Borrower is electing the LIBOR Rate Option and (ii) the LIBOR Business Day upon which the applicable LIBOR Rate
Interest Period is to commence. The Applicable Rate for any portion of the Loan with respect to which Borrower has elected the
LIBOR Rate Option shall revert to the Adjusted Daily LIBOR Rate as of the last day of the LIBOR Rate Interest Period applicable
thereto (unless Borrower again exercises the LIBOR Rate Option for such portion of the Loan). Lender shall be under no duty to
notify Borrower that the Applicable Rate on any portion of the Loan is about to revert from the Adjusted One Month LIBOR Rate
to the Adjusted Daily LIBOR Rate. With the exception of advances to pay interest on the Loan, the LIBOR Rate Option may be exercised
by Borrower only with respect to any portion of the Loan equal to or in excess of $500,000.00. At no time may there be more than
four (4) LIBOR Rate Interest Periods in effect with respect to the Loan. Notwithstanding the foregoing, if Borrower shall elect
a LIBOR Rate Option, only so much of the outstanding principal amount of the Loan as would not become due and payable during the
applicable LIBOR Rate Interest Period shall accrue interest at the Adjusted One Month LIBOR Rate and the remaining principal balance
shall accrue interest at the Adjusted Daily LIBOR Rate.

 

    	- 18 -

    	 

    

 

(d)          If
Lender determines (which determination shall be conclusive and binding upon Borrower, absent manifest error) (i) that Dollar deposits
in an amount approximately equal to the portion of the Loan for which Borrower has exercised the LIBOR Rate Option for the designated
LIBOR Rate Interest Period are not generally available at such time in the London interbank market for deposits in Dollars, (ii)
that the rate at which such deposits are being offered will not adequately and fairly reflect the cost to Lender of maintaining
a LIBOR Rate on such portion of the Loan or of funding the same for such LIBOR Rate Interest Period due to circumstances affecting
the London interbank market generally, (iii) that reasonable means do not exist for ascertaining a LIBOR Rate, or (iv) that an
Adjusted LIBOR Rate would be in excess of the maximum interest rate which Borrower may by law pay, then, in any such event, Lender
shall so notify Borrower and all portions of the Loan bearing interest at an Adjusted LIBOR Rate that are so affected shall, as
of the date of such notification with respect to an event described in clause (ii) or (iv) above, or as of the expiration
of the applicable LIBOR Rate Interest Period with respect to an event described in clause (i) or (iii) above, bear
interest at the Adjusted Prime Rate until such time as the situations described above are no longer in effect or can be avoided
by Borrower exercising a LIBOR Rate Option for a different LIBOR Rate Interest Period.

 

(e)           Interest
at the Applicable Rate (or Default Rate) shall be calculated for the actual number of days elapsed on the basis of a 360-day year,
including the first date of the applicable period to, but not including, the date of repayment.

 

(f)           Borrower
shall pay all Breakage Costs incurred from time to time by Lender upon demand.

 

(g)          If
the introduction of or any change in any Law, regulation or treaty, or in the interpretation thereof by any Governmental Authority
charged with the administration or interpretation thereof, shall make it unlawful for Lender to maintain the Applicable Rate at
an Adjusted LIBOR Rate with respect to the Loan or any portion thereof, or to fund the Loan or any portion thereof in Dollars
in the London interbank market, or to give effect to its obligations regarding the LIBOR Rate Option as contemplated by the Loan
Documents, then (i) Lender shall notify Borrower that Lender is no longer able to maintain the Applicable Rate at an Adjusted
LIBOR Rate, (ii) the LIBOR Rate Option shall immediately terminate, (iii) the Applicable Rate for any portion of the Loan for
which the Applicable Rate is then an Adjusted LIBOR Rate shall automatically be converted to the Adjusted Prime Rate, and (iv)
Borrower shall pay to Lender the amount of Breakage Costs (if any) incurred in connection with such conversion. Thereafter, Borrower
shall not be entitled to exercise the LIBOR Rate Option until such time as the situation described herein is no longer in effect
or can be avoided by Borrower exercising a LIBOR Rate Option for a LIBOR Rate Interest Period.

 

(h)          The
Loan shall bear interest at the Default Rate at any time at which an Event of Default shall exist.

 

5.2           Interest
Rate Agreements.

 

(a)          Any
indebtedness incurred pursuant to an Interest Rate Agreement entered into by Borrower and Lender shall constitute indebtedness
evidenced by the Note and secured by the Mortgage and the other Loan Documents to the same extent and effect as if the terms and
provisions of such Interest Rate Agreement were set forth herein, whether or not the aggregate of such indebtedness, together
with the disbursements made by Lender of the proceeds of the Loan, shall exceed the face amount of the Note.

 

    	- 19 -

    	 

    

 

(b)          Borrower
hereby collaterally assigns to Lender for the benefit of Lender any and all Interest Rate Protection Products purchased or to
be purchased by Borrower in connection with the Loan, as additional security for the Loan, and agrees to provide Lender with any
additional documentation requested by Lender in order to confirm or perfect such security interest during the term of the Loan.
If Borrower obtains an Interest Rate Protection Product from a party other than Lender, Borrower shall deliver to Lender such
third party’s consent to such collateral assignment. No Interest Rate Protection Product purchased from a third party may
be secured by an interest in Borrower or the Project.

 

(c)           Except
as otherwise provided in this paragraph, the Borrower shall not enter into any Interest Rate Protection Product. At Borrower's
option, Borrower may institute an interest rate hedging program through the purchase of an Interest Rate Protection Product with
respect to the Loan. The Interest Rate Protection Product, the portion of the Loan (if less than the entire Loan Amount) to which
such Interest Rate Protection Product shall apply, and the financial institution providing the Interest Rate Protection Product,
shall be subject to Lender's prior reasonable written approval. Borrower shall afford Lender a right of first opportunity to provide
all Interest Rate Protection Products but shall not be required to purchase such Interest Rate Protection Product from Lender.

 

ARTICLE
6

COSTS OF MAINTAINING LOAN

 

6.1           Increased
Costs and Capital Adequacy.

 

(a)          Borrower
recognizes that the cost to Lender of maintaining the Loan or any portion thereof may fluctuate and, Borrower agrees to pay Lender
additional amounts to compensate Lender for any increase in its actual costs incurred in maintaining the Loan or any portion thereof
outstanding or for the reduction of any amounts received or receivable from Borrower as a result of:

 

(i)            any
change after the date hereof in any applicable Law, regulation or treaty, or in the interpretation or administration thereof,
or by any domestic or foreign court, (A) changing the basis of taxation of payments under this Agreement to Lender (other than
taxes imposed on all or any portion of the overall net income or receipts of Lender), or (B) imposing, modifying or applying any
reserve, special deposit or similar requirement against assets of, deposits with or for the account of, credit extended by, or
any other acquisition of funds for loans by Lender (which includes the Loan or any applicable portion thereof) (provided,
however, that Borrower shall not be charged again the Reserve Percentage already accounted for in the definition of the
Adjusted LIBOR Rate),, or (C) imposing on Lender, or the London interbank market generally, any other condition affecting the
Loan, provided that the result of the foregoing is to increase the cost to Lender of maintaining the Loan or any portion thereof
or to reduce the amount of any sum received or receivable from Borrower by Lender under the Loan Documents; or

 

(ii)           the
maintenance by Lender of reserves in accordance with reserve requirements promulgated by the Board of Governors of the Federal
Reserve System of the United States with respect to “Eurocurrency Liabilities” of a similar term to that of the applicable
portion of the Loan (without duplication for reserves already accounted for in the calculation of a LIBOR Rate pursuant to the
terms hereof).

 

(b)          If
the application of any Law, rule, regulation or guideline adopted or arising out of the Basle Committee on Banking Regulations
and Supervisory Practices entitled “International Convergence of Capital Measurement and Capital Standards”, or the
adoption after the date hereof of any other Law, rule, regulation or guideline regarding capital adequacy, or any change after
the date hereof in any of the foregoing, or in the interpretation or administration thereof by any domestic or foreign Governmental
Authority, central bank or comparable agency charged with the interpretation or administration thereof, or compliance by Lender,
with any request or directive regarding capital adequacy (whether or not having the force of law) of any such authority, central
bank or comparable agency, has the effect of reducing the rate of return on Lender’s capital to a level below that which
Lender would have achieved but for such application, adoption, change or compliance (taking into consideration the policies of
Lender with respect to capital adequacy), then, from time to time Borrower shall pay to Lender such additional amounts as will
compensate Lender for such reduction with respect to any portion of the Loan outstanding.

 

    	- 20 -

    	 

    

 

(c)          Any
amount payable by Borrower under subsection (a) or subsection (b) of this Section 6.1 shall be paid within
five (5) Business Days of receipt by Borrower of a certificate signed by an authorized officer of Lender setting forth the amount
due and the basis for the determination of such amount, which statement shall be conclusive and binding upon Borrower, absent
manifest error. Failure on the part of Lender to demand payment from Borrower for any such amount attributable to any particular
period shall not constitute a waiver of Lender’s right to demand payment of such amount for any subsequent or prior period.
Lender shall use reasonable efforts to deliver to Borrower prompt notice of any event described in subsection (a) or (b)
above, of the amount of the reserve and capital adequacy payments resulting therefrom and the reasons therefor and of the
basis of calculation of such amount; provided, however, that any failure by Lender to so notify Borrower shall not
affect Borrower’s obligation to pay the reserve and capital adequacy payment resulting therefrom.

 

6.2           Borrower
Withholding.

 

If
by reason of a change in any applicable Laws occurring after the date hereof, Borrower is required by Law to make any deduction
or withholding in respect of any taxes (other than taxes imposed on or measured by the net income of Lender or any franchise tax
imposed on Lender), duties or other charges from any payment due under the Note to the maximum extent permitted by law, the sum
due from Borrower in respect of such payment shall be increased to the extent necessary to ensure that, after the making of such
deduction or withholding, Lender receives and retains a net sum equal to the sum which it would have received had no such deduction
or withholding been required to be made.

 

ARTICLE
7

LOAN FEES, EXPENSES AND ADVANCES 

 

7.1           Loan
and Administration Expenses.

 

Borrower
unconditionally agrees to pay all expenses of the Loan, as set forth in this Agreement, including all amounts payable pursuant
to Sections 7.2 and 7.3 and any and all other fees owing to Lender pursuant to the Loan Documents or any separate
fee agreement, and also including, without limiting the generality of the foregoing, to the extent required under this Agreement,
all recording, filing and registration fees and charges, mortgage or documentary taxes, all insurance premiums, title insurance
premiums and other charges of the Title Insurer, printing and photocopying expenses, survey fees and charges, cost of certified
copies of instruments, cost of premiums on surety company bonds and the Title Policy, charges of the Title Insurer or other escrowee
for administering disbursements, all fees and disbursements of Lender’s Consultant, all appraisal fees, insurance consultant’s
fees, environmental consultant’s fees, reasonable travel related expenses and all reasonable costs and expenses incurred
by Lender in connection with the determination of whether or not Borrower has performed the obligations undertaken by Borrower
hereunder or has satisfied any conditions precedent to the obligations of Lender hereunder and, if any default or Event of Default
occurs hereunder or under any of the Loan Documents or if the Loan or Note or any portion thereof is not paid in full when and
as due, all costs and expenses of Lender (including, without limitation, court costs and reasonable and actual attorney’s
fees at standard hourly rates without regard to any presumptive statutory attorney’s fees incurred in attempting to enforce
payment of the Loan and expenses of Lender incurred (including court costs and counsel’s fees and disbursements and fees
and costs of paralegals) in attempting to realize, while a default or Event of Default exists, on any security or incurred in
connection with the sale or disposition (or preparation for sale or disposition) of any security for the Loan. Borrower agrees
to pay all brokerage, finder or similar fees or commissions payable in connection with the transactions contemplated hereby and
shall indemnify and hold Lender harmless against all claims, liabilities, costs and expenses (including reasonable and actual
attorney’s fees at standard hourly rates without regard to any presumptive statutory attorney’s fees and expenses)
incurred in relation to any claim by broker, finder or similar person.

 

    	- 21 -

    	 

    

 

7.2           Origination
Fee.

 

Borrower
shall pay to Lender on or before the date of this Agreement an origination fee in the amount of One Hundred Thirty-Seven Thousand
Five Hundred and No/100 Dollars ($137,500.00). Such fee is fully earned and non-refundable.

 

7.3           Exit
Fee. 

 

Upon
the repayment of the Loan (whether at the Maturity Date or at any other date), Borrower will pay to Lender an exit fee equal to
one percent (1.0%) of the outstanding principal balance of the Loan (the “Exit Fee”); unless (a) the Loan is
repaid with the proceeds of a permanent loan from Lender or an affiliate of Lender; (b) the Loan is repaid with the proceeds of
a permanent loan arranged by Lender or an affiliate of Lender through another investor or lender (including, but not limited to,
Fannie Mae, Freddie Mac, HUD or GinnieMae); (c) the Loan is repaid as a result of the sale of the Project to an unrelated third
party; or (d) Borrower presents to Lender a bona fide term sheet delivered to the Borrower by a third party lender to refinance
the Loan with a permanent loan and within fifteen (15) days thereafter Lender declines to offer a permanent loan containing substantially
the same economic and other business terms as those offered by such third party lender in such term sheet. The Exit Fee shall
be deemed to be earned upon the repayment of the Loan without the occurrence of the events set forth in subparts (a), (b), (c)
and (d) of this Section 7.3. For the avoidance of doubt, no Exit Fee shall be deemed due and payable in connection with any foreclosure
of the Loan or any deed in lieu of foreclosure.

 

7.4           Lender’s
Attorneys’ Fees and Disbursements.

 

Borrower
agrees to pay Lender’s actual and reasonable attorney fees and actual third party disbursements incurred in connection with
this Loan, including: (a) the preparation of this Agreement, any intercreditor agreements and the other Loan Documents and
the preparation of the closing binders; (b) the disbursement, syndication, amendment, and administration of the Loan; and (c)
the enforcement of the terms of this Agreement and the other Loan Documents.

 

7.5           Time
of Payment of Fees and Expenses.

 

Borrower
shall pay all expenses and fees incurred as of the Loan Opening on the Loan Opening Date (unless sooner required herein). At the
time of the Opening of the Loan, Lender may pay from the proceeds of the initial disbursement of the Loan (to the extent provided
for in the Budget) all Loan expenses and all fees payable to Lender. Lender may require the payment of outstanding fees and expenses
as a condition to any disbursement of the Loan. Upon the occurrence and during the continuance of an Event of Default, Lender
is hereby authorized, without any specific request or direction by Borrower, to make disbursements from time to time in payment
of or to reimburse Lender for all Loan expenses and fees (whether or not, at such time, there may be any undisbursed amounts of
the Loan allocated in the Budget for the same).

 

7.6           Expenses
and Advances Secured by Loan Documents.

 

Any
and all advances or payments made by Lender under this Article 7 from time to time, and any amounts expended by Lender
pursuant to Section 20.1(a), shall, as and when advanced or incurred, constitute additional indebtedness evidenced by the
Note and secured by the Mortgage and the other Loan Documents.

 

    	- 22 -

    	 

    

 

7.7           Right
of Lender to Make Advances to Cure Borrower’s Defaults.

 

In
the event that Borrower fails to perform any of Borrower’s covenants, agreements or obligations contained in this Agreement
or any of the other Loan Documents (after the expiration of applicable grace periods, except in the event of an emergency or other
exigent circumstances which, in each case, would in Lender’s reasonable judgment impair the value of Lender’s security
for the Loan), Lender may (but shall not be required to) perform any of such covenants, agreements and obligations, and any amounts
expended by Lender in so doing shall constitute additional indebtedness evidenced by the Note and secured by the Mortgage and
the other Loan Documents and shall bear interest at the Default Rate.

 

ARTICLE
8

NON-CONSTRUCTION REQUIREMENTS PRECEDENT

TO THE OPENING OF THE LOAN

 

8.1           Non-Construction
Conditions Precedent.

 

Borrower
agrees that Lender’s obligation to open the Loan and thereafter to make further disbursements of proceeds thereof is conditioned
upon Borrower’s delivery, performance and satisfaction of the following conditions precedent in form and substance satisfactory
to Lender in its reasonable discretion:

 

(a)          Equity:
Borrower shall have provided evidence reasonably satisfactory to Lender that Borrower’s cash equity invested in the Project
is not less than the difference between the total Project cost as set forth in the Budget and the maximum Loan Amount; provided,
however, in no event shall Borrower’s cash equity in the Project (including the prior acquisition of the Land) be
less than twenty-five percent (25%) of the total cost of the Project as set out in the Budget approved by Lender hereunder. Borrower’s
cash equity must be either (i) deposited with the Lender on or prior to the date of this Agreement and disbursed prior to the
first disbursement of Loan proceeds; or (ii) used to pay direct Project costs (including the prior acquisition of the Land) approved
by Lender with evidence of payment delivered to Lender prior to the first disbursement of Loan proceeds; provided, however, that
the value of Land as reflected in the Closing Statement by which Borrower secured the Project, a copy of which has been delivered
to Lender, shall be included and credited to Borrower in the determination of minimum equity hereunder.

 

(b)          Title
and Other Documents: Borrower shall have furnished to Lender the Title Policy together with legible copies of all title exception
documents cited in the Title Policy and all other legal documents affecting the Project or the use thereof;

 

(c)          Survey:
Borrower shall have furnished to Lender an ALTA/ACSM “Class A” Land Title Survey of the Project. Said survey shall
be dated no earlier than ninety (90) days prior to the Loan Opening, shall be made (and certified to have been made) as set forth
in Exhibit D attached hereto and made a part hereof. Such survey shall be sufficient to permit issuance of the Title Policy
in the form required by this Agreement. Such survey shall include the legal description of the Land;

 

(d)          Insurance
Policies: Subject to Section 12.8, Borrower shall have furnished to Lender not less than ten (10) days prior to the
date of this Agreement policies or binders evidencing that insurance coverages are in effect with respect to the Project and Borrower,
in accordance with the Insurance Requirements attached hereto as Exhibit E, for which the premiums have been fully prepaid
with endorsements satisfactory to Lender.

 

    	- 23 -

    	 

    

 

(e)          No
Litigation: Borrower shall have furnished evidence reasonably satisfactory to Lender that no litigation or proceedings shall
be pending or threatened (in writing) which could or might cause a Material Adverse Change with respect to Borrower, any Guarantor
or the Project;

 

(f)           Utilities:
Borrower shall have furnished to Lender (by way of utility letters or otherwise) evidence reasonably satisfactory to Lender establishing
to the satisfaction of Lender that the Project when constructed will have adequate water supply, storm and sanitary sewerage facilities,
telephone, gas, electricity, fire and police protection, means of ingress and egress to and from the Project and public highways
and any other required public utilities and that the Project is benefited by insured easements as may be required for any of the
foregoing;

 

(g)          Attorney
Opinions: Borrower shall have furnished to Lender an opinion from counsel for Borrower and Guarantor covering due authorization,
execution and delivery and enforceability of the Loan Documents and also containing such other legal opinions as Lender shall
reasonably require;

 

(h)          Appraisal:
Lender shall have obtained an Appraisal, satisfactory to Lender in all respects, indicating that the value of the Project (based
upon the Project’s stabilized value upon completion of Construction) is such that the ratio (expressed as a percentage)
of the maximum Loan amount to such value of the Project is not less than seventy-five percent (75%);

 

(i)           Searches:
Borrower shall have furnished to Lender current bankruptcy, federal tax lien and judgment searches and searches of all Uniform
Commercial Code financing statements filed in each place UCC Financing Statements are to be filed hereunder, demonstrating the
absence of adverse claims;

 

(j)           Financial
Statements: Borrower shall have furnished to Lender current annual financial statements of Borrower, the Guarantors, the General
Contractor and such other persons or entities connected with the Loan as Lender may reasonably request, each in form and substance
and certified by such individual as acceptable to Lender. Borrower and the Guarantors shall provide such other additional financial
information Lender reasonably requires;

 

(k)          Pro
Forma Projection: Borrower shall have furnished to Lender a Pro Forma Projection covering the succeeding two year period;

 

(l)            Management
Agreements: Borrower shall have delivered to Lender executed copies of any leasing, management and development agreements
entered into by Borrower in connection with the Construction and/or the operation of the Project;

 

(m)          Flood
Hazard: Lender has received evidence that the Project is not located in an area designated by the Secretary of Housing and
Urban Development as a special flood hazard area, or flood hazard insurance acceptable to Lender in its sole discretion;

 

(n)          Zoning:
If the Title Policy does not include a zoning endorsement, Borrower shall have furnished to Lender a legal opinion or zoning letter
as to compliance of the Project with zoning and similar laws;

 

(o)          Organizational
Documents: Borrower shall have furnished to Lender proof satisfactory to Lender of authority, formation, organization and
good standing in the State of its incorporation or formation and, if applicable, qualification as a foreign entity in good standing
in the State where the Project is located of all corporate, partnership, trust and limited liability company entities (including
Borrower and each entity Guarantor (if any)) executing any Loan Documents, whether in their own name or on behalf of another entity.
Borrower shall also provide certified resolutions in form and content satisfactory to Lender, authorizing execution, delivery
and performance of the Loan Documents, and such other documentation as Lender may reasonably require to evidence the authority
of the persons executing the Loan Documents;

 

    	- 24 -

    	 

    

 

(p)          No
Default: There shall be no uncured Default or Event of Default by Borrower hereunder;

 

(q)          Easements:
Borrower shall have furnished Lender all easements reasonably required for the construction, maintenance or operation of the Project
and such easements shall be insured by the Title Policy; and

 

(r)           Additional
Documents: Borrower shall have furnished to Lender such other materials, documents, papers or requirements regarding the Project,
Borrower and any Guarantor as Lender shall reasonably request.

 

ARTICLE
9

CONSTRUCTION REQUIREMENTS PRECEDENT

TO THE OPENING OF THE LOAN

 

9.1           Required
Construction Documents.

 

Borrower
shall cause to be furnished to Lender the following, in form and substance satisfactory to Lender and Lender’s Consultant
in all respects, for Lender’s approval in its reasonable discretion prior to the Opening of the Loan:

 

(a)          Fully
executed copies of the following, each satisfactory to Lender and Lender’s Consultant in all respects: (i) a fixed
or guaranteed maximum price General Contract with the General Contractor; and (ii) all contracts with Architect and Engineer and
any other architects and engineers;

 

(b)          A
schedule of values, including a trade payment breakdown, setting forth a description of all contracts let by Borrower and/or the
General Contractor for the design, engineering, construction and equipping of the Improvements;

 

(c)          An
initial sworn statement of the General Contractor, reasonably approved by Borrower, Architect and Lender’s Consultant covering
all work done and to be done, together with lien waivers covering all work and materials for which payments have been made by
Borrower prior to the Loan Opening;

 

(d)          A
Subordination Agreement with respect to the TIC Agreement and Trust Agreement executed by Borrower, Eldorado, LLC, Spyglass, LLC,
BR/CDP UCFP Venture, LLC and Lender; in addition, Borrower shall deliver the Subordination Agreement in recordable form and executed
by the foregoing parties not later than May 21, 2014;

 

(e)          Copies
of each of the Required Permits, except for those Required Permits which cannot be issued until completion of Construction, in
which event such Required Permits will be obtained by Borrower on a timely basis in accordance with all recorded maps and conditions,
and applicable building, land use, zoning and environmental codes, statutes and regulations and will be delivered to Lender at
the earliest possible date. Notwithstanding the foregoing, (i) building permits required for Construction will be obtained by
Borrower and copies thereof delivered to Lender not later than July 15, 2014, and (ii) Lender shall have no obligation to fund
Loan proceeds in excess of One Thousand and No/100 Dollars ($1,000.00) until such building permits are obtained and delivered,
provided, however, that upon delivery to Lender of a letter from the applicable Governmental Authority or other form of written
communication customarily provided by the applicable Governmental Authority that the Required Permits will be issued upon payment
of a fee or fees, Lender will agree to fund from Loan proceeds an amount needed to obtain Required Permits, including without
limitation impact fees or other fees due to Orange County otherwise required to obtain Required Permits.

 

    	- 25 -

    	 

    

 

(f)           Full
and complete detailed Plans and Specifications for the Improvements in duplicate, prepared by the Architect;

 

(g)          The
Construction Schedule;

 

(h)          The
Soil Report;

 

(i)           The
Environmental Report;

 

The
Environmental Report shall, at a minimum, (i) demonstrate the absence of any existing or potential Hazardous Material contamination
or violations of environmental Laws at the Project, except as acceptable to Lender in its sole and absolute discretion; (ii) include
the results of all sampling or monitoring to confirm the extent of existing or potential Hazardous Material contamination at the
Project, including the results of leak detection tests for each underground storage tank located at the Project, if any; (iii)
describe response actions appropriate to remedy any existing or potential Hazardous Material contamination, and report the estimated
cost of any such appropriate response; (iv) confirm that any prior removal of Hazardous Material or underground storage tanks
from the Project was completed in accordance with applicable Laws; and (v) confirm whether or not the Land is located in a wetlands
district;

 

(j)            A
report from Lender’s Consultant which contains an analysis of the Plans and Specifications, the Budget, the Construction
Schedule, the General Contract, all Subcontracts then existing and the Soil Report. Such report shall be solely for the benefit
of Lender and contain (i) an analysis satisfactory to Lender demonstrating the adequacy of the Budget to complete the Project
and (ii) a confirmation that the Construction Schedule is realistic. Lender’s Consultant shall monitor Construction
of the Project and shall visit the Project at least one (1) time each month, and shall certify as to amounts of construction costs
for all requested fundings;

 

(k)           The
Architect’s Certificate;

 

(l)           Certification
from an engineer or other professional reasonably acceptable to Lender in a form acceptable to Lender confirming that any wetlands
located on the Land will not preclude the development of the Project;

 

(m)          A
Notice of Commencement complying with applicable state or local law; and

 

(n)           Such
other papers, materials and documents as Lender may reasonably require with respect to the Construction.

 

ARTICLE
10

BUDGET AND CONTINGENCY FUND

 

10.1         Budget.

 

Disbursement
of the Loan shall be governed by the Budget for the Project, in form and substance acceptable to Lender in Lender’s reasonable
discretion. The Budget shall specify the amount of cash equity invested in the Project, and all costs and expenses of every kind
and nature whatever to be incurred by Borrower in connection with the Project. The Budget shall include, in addition to the Budget
Line Items described in Section 10.2 below, the Contingency Fund described in Section 10.3 below, and amounts satisfactory
to Lender for soft costs and other reserves acceptable to Lender. The initial Budget (which is deemed approved by Lender) is attached
hereto as Exhibit G and made a part hereof. Once the Budget is approved by Lender all changes to the Budget shall
in all respects be subject to the prior written approval of Lender, not to be unreasonably withheld, conditioned or delayed.

 

    	- 26 -

    	 

    

 

10.2         Budget
Line Items.

 

The
Budget shall include as line items (“Budget Line Items”), to the extent determined to be applicable by Lender
in its reasonable discretion, the cost of all labor, materials, equipment, fixtures and furnishings needed for the completion
of the Construction, and all other costs, fees and expenses relating in any way whatsoever to the Construction of the Improvements,
operating deficits, real estate taxes, and all other sums due in connection with the Construction and operation of the Project,
the Loan, and this Agreement. Borrower agrees that all Loan proceeds disbursed by Lender shall be used only for the Budget Line
Items for which such proceeds were disbursed. With the prior approval of Lender (which shall not be unreasonably withheld, conditioned
or delayed), any cost savings, actual or estimated, affecting any Budget Line Items, other than the Interest Reserve, may be reallocated
by Borrower to any other line item within the Budget.

 

Lender
shall not be obligated to disburse any amount for any category of costs set forth as a Budget Line Item which is greater than
the amount set forth for such category in the applicable Budget Line Item. Borrower shall pay as they become due all amounts set
forth in the Budget with respect to costs to be paid for by Borrower.

 

10.3         Contingency
Fund.

 

The
Budget shall contain a Budget Line Item designated for the Contingency Fund. Borrower may from time to time request that the Contingency
Fund be reallocated to pay needed costs of the Project (but in no event shall the Contingency Fund be reallocated to the Development
Fee). Such requests shall be subject to Lender’s written approval in its reasonable discretion. Notwithstanding the foregoing,
Borrower shall be entitled without Lender’s written approval (i) to reallocate to other Budget Line Items (excluding the
Development Fee) the soft cost portion of the Contingency Fund; and (ii) with respect to the hard cost portion of the Contingency
Fund, to reallocate to other Budget Line Items (excluding the Development Fee) a portion of the hard cost portion of the Contingency
Fund equal to the percentage of completion of the Improvements up to an aggregate amount of One Hundred Thousand and No/100th
Dollars ($100,000.00); provided, however, that for the avoidance of doubt, any reallocation of the hard cost portion of
the Contingency Fund in excess of One Hundred Thousand and No/100th Dollars ($100,000.00) must be approved in writing
by Lender, such approval not to be unreasonably withheld. For example, if the Improvements are twenty-five percent (25%) complete,
then Borrower’s right to reallocate the hard cost portion of the Contingency Fund (not exceeding One Hundred Thousand and
No/100th Dollars [$100,000.00]) without Lender’s written approval shall apply to twenty-five percent (25%) of
the Contingency Fund (not exceeding One Hundred Thousand and No/100th Dollars [$100,000.00]).

 

Borrower
agrees that the decision with respect to utilizing portions of the Contingency Fund in order to keep the Loan In Balance shall
be made by Lender in its reasonable discretion, and that Lender may require Borrower to make a Deficiency Deposit even if funds
remain in the Contingency Fund. Once the Project begins to generate Net Operating Income, Borrower may only borrow from the Loan
interest in excess of the Net Operating Income so generated.

 

    	- 27 -

    	 

    

 

10.4         Optional
Method for Payment of Interest.

 

For
Borrower’s benefit, the Budget includes a Budget Line Item for interest payments on the Loan and, with Lender’s approval,
amounts due from Borrower under any Interest Rate Agreement with respect to the Loan. Borrower hereby authorizes Lender from time
to time, for the mutual convenience of Lender and Borrower, to disburse Loan proceeds to pay all the then accrued interest on
the Note and to pay amounts due from Borrower under any Interest Rate Agreement with respect to the Loan, regardless of whether
Borrower shall have specifically requested a disbursement of such amount. Any such disbursement, if made, shall be added to the
outstanding principal balance of the Note and shall, when disbursed, bear interest at the Applicable Rate. The authorization hereby
granted, however, shall not obligate Lender to make disbursements of the Loan for interest payments or any amount due under any
Interest Rate Agreement (except upon Borrower’s qualifying for and requesting disbursement of that portion of the proceeds
of the Loan allocated for such purposes in the Budget) nor prevent Borrower from paying accrued interest or amounts due under
any Interest Rate Agreement from its own funds. Provided no Event of Default or material Default has occurred and is continuing,
Lender agrees to make such disbursements for interest payments prior to the date on which such interest payments are due hereunder.

 

ARTICLE
11

SUFFICIENCY OF LOAN

 

11.1         Loan
In Balance.

 

Anything
contained in this Agreement to the contrary notwithstanding, it is expressly understood and agreed that the Loan shall at all
times be “In Balance”, on a Budget Line Item and an aggregate basis. A Budget Line Item shall be deemed to be “In
Balance” only if Lender in its reasonable discretion determines that the amount of such Budget Line Item,
after taking into account any portion of the Contingency Fund which Borrower is permitted to reallocate
without Lender's consent pursuant to Section 10.3 of this Agreement and reallocated cost savings approved by Lender in accordance
with Section 10.2 of this Agreement and change orders expressly permitted under Section 15.1(c) or otherwise approved in writing
by Lender, is sufficient for its intended purpose. The Loan shall be deemed to be “In Balance” in the aggregate
only when the total of the undisbursed portion of the Loan, less any portion of the Contingency Fund which Borrower is not entitled
to re-allocate without Lender's prior reasonable approval pursuant to Section 10.3 above, and after
taking into account reallocated cost savings approved by Lender in accordance with Section 10.2 of this Agreement and change orders
expressly permitted under Section 15.1(c) or otherwise approved in writing by Lender, equals or exceeds the aggregate of (a) the
costs required to complete the construction of the Project in accordance with the Plans and Specifications and the Budget; (b)
the amounts to be paid as retainages to persons who have supplied labor or materials to the Project; (c) the amount in excess
of the projected (i.e. projected pursuant to the pro forma delivered per Section 8.1(k)) Net Operating Income required to pay
interest on the Loan through the Maturity Date; and (d) all other hard and soft costs not yet paid for in connection with the
Project, as such costs and amounts described in clauses (a), (b), (c) and (d) may be estimated and/or approved in
writing by Lender from time to time. Borrower agrees that if for any reason, in Lender’s reasonable discretion and upon
receipt of certification from Lender’s construction consultants confirming the same, the amount of such undistributed Loan
proceeds shall at any time be or become insufficient for such purpose regardless of how such condition may be caused, Borrower
will, within ten (10) days after written request by Lender, deposit the deficiency with Lender (“Deficiency Deposit”).
The Deficiency Deposit shall first be exhausted before any further disbursement of Loan proceeds shall be made. Lender shall not
be obligated to make any Loan disbursements if and for as long as the Loan is not In Balance. 

 

ARTICLE
12

CONSTRUCTION PAYOUT REQUIREMENTS

 

12.1          Applicability
of Sections.

 

The
provisions contained in this Article 12 shall apply to the Opening of the Loan and to all disbursements of proceeds
during Construction.

 

    	- 28 -

    	 

    

 

12.2         Monthly
Payouts.

 

After
the Opening of the Loan, further disbursements shall be made during Construction from time to time as the Construction progresses,
but Lender shall have no obligation to make disbursements (excluding disbursements for debt service) more frequently than once
in each calendar month; provided, however, that Lender will consider other occasional disbursements of Loan proceeds for one item
per month (but Lender shall have no obligation to make such occasional disbursements and in no event shall Lender be obligated
to consider more than one full draw request per calendar month). At Lender’s option, disbursements may be made by Lender
into an escrow and subsequently disbursed to Borrower by the Title Insurer. If such option is exercised, those Loan proceeds shall
be deemed to be disbursed to Borrower from the date of deposit into that escrow and interest shall accrue on those proceeds from
that date, regardless of the date such proceeds are released by the Title Insurer.

 

12.3         Documents
to be Furnished for Each Disbursement.

 

As
a condition precedent to each disbursement of the Loan proceeds (including the initial disbursement at the Opening of the Loan),
Borrower shall furnish or cause to be furnished to Lender the following documents covering each disbursement, in form and substance
reasonably satisfactory to Lender:

 

(a)          A
completed Borrower’s Certificate in the form of Exhibit H attached hereto and made a part hereof and a completed
Soft and Hard Cost Requisition Form in the form of Exhibit I attached hereto and made a part hereof, each executed by the
Authorized Representative of Borrower;

 

(b)          A
completed standard AIA Form G702 and Form G703 signed by the General Contractor, together with General Contractor’s sworn
statements and unconditional waivers of lien, and all subcontractors’, material suppliers’ and laborers’ conditional
waivers of lien, covering all work, paid with the proceeds of the prior draw requests, together with such invoices, contracts
or other supporting data as Lender may require to evidence that all costs for which disbursement is sought have been incurred;

 

(c)          Paid
invoices or other evidence reasonably satisfactory to Lender that fixtures and equipment, if any, have been paid for and are free
of any lien or security interest therein;

 

(d)          A
“Construction Loan Update” endorsement to the Title Policy issued to Lender in the form of Exhibit L attached
hereto and made a part hereof as covering the date of disbursement and showing the Mortgage as a first, prior and paramount lien
on the Project subject only to the Permitted Exceptions and real estate taxes that have accrued but are not yet due and payable
and particularly that nothing has intervened to affect the validity or priority of the Mortgage;

 

(e)          Copies
of any proposed or executed Change Orders on standard AIA G701 form which have not been previously furnished to Lender and which
require and are not valid without the signatures of the General Contractor, Borrower and Architect;

 

(f)           Copies
of all construction contracts (including Subcontracts) which have been executed since the last disbursement; and an updated list
of subcontractors (including contact information therefor);

 

(g)          All
Required Permits and all other Governmental Approvals then needed in connection with the Project; and

 

(h)          Such
other instruments, documents and information as Lender or the Title Insurer may reasonably request.

 

    	- 29 -

    	 

    

 

Disbursements
shall be made approximately ten (10) days after receipt of all information required by Lender to approve the requested disbursements.
To the extent that any submittal by Borrower contains insufficient information, Lender agrees to provide notice of the same within
ten (10) days of submittal.

 

12.4         Retainages.

 

At
the time of each disbursement of Loan proceeds, the Applicable Retention Amount of the total amount then due the General Contractor
and the various contractors, subcontractors and material suppliers for costs of the Construction shall be withheld from the amount
disbursed. The retained Loan amounts for the Construction costs will be disbursed only at the time of the final disbursement of
Loan proceeds under Article 13 below; provided, however, upon the satisfactory completion of one hundred percent (100%)
of the work with respect to any trade (including any trade performed by the General Contractor) or the delivery of all materials
pursuant to a purchase order in accordance with the Plans and Specifications as certified by the Architect and the Lender’s
Consultant, Lender may decide on a case by case basis (but shall not be obligated) to permit retainages with respect to such trade
or order, as the case may be, to be disbursed to Borrower upon the Lender’s Consultant’s reasonable approval of all
work and materials and Lender’s receipt of a final waiver of lien with respect to such completed work or delivered materials.

 

12.5         Disbursements
for Materials Stored On-Site.

 

Any
requests for disbursements which in whole or in part relate to materials, equipment or furnishings which Borrower owns and which
are not incorporated into the Improvements as of the date of the request for disbursement, but are to be temporarily stored at
the Project, shall be made in an aggregate amount not to exceed One Million and No/100th Dollars ($1,000,000.00). Any
such request must be accompanied by evidence satisfactory to Lender that (a) such stored materials are included within the coverages
of insurance policies carried by Borrower, (b) the ownership of such materials is vested in Borrower free of any liens and
claims of third parties, (c)  such materials are properly insured and protected against theft or damage, (d) the Lender’s
Consultant has viewed and inspected the stored materials, and (e) in the reasonable opinion of the Lender’s Consultant the
stored materials are physically secured and can be incorporated into the Project within ninety (90) days. Lender may require separate
Uniform Commercial Code financing statements to cover any such stored materials.

 

12.6         Disbursements
for Offsite Materials.

 

Lender
may in its sole discretion, but shall not be obligated to, approve disbursements for materials stored off-site, provided, however,
that Lender shall not unreasonably withhold such approval if (a) all of the requirements of Section 12.5(a) – (e)
shall have been satisfied with respect to such disbursement; (b) the materials to be stored off-site and to be used in the
Construction are not commodity items but are uniquely fabricated for the Construction; (c) any off-site materials are stored at
a third party owned and operated site that Lender reasonably approves, including storage in a bonded warehouse in the County in
which the Project is located; and (d) the cost of materials stored off-site shall not at any one time exceed One Hundred Thousand
and No/100th Dollars ($100,000.00).

 

12.7         Disbursements
for Cost Savings.

 

Upon
satisfaction of all of the following conditions, and with Lender’s approval, not to be unreasonably withheld, Borrower may
receive a disbursement in the sum of all actual cost savings affecting any Budget Line Items other than the Interest Reserve (such
cost savings to be reasonably approved by Lender) (the “Cost Savings Disbursement”):

 

    	- 30 -

    	 

    

 

(a)          All
of the conditions set forth in Section 13.1 for the final disbursement shall have been complied with and all other conditions
in this Agreement for disbursements shall have been complied with; and

 

(b)          Lender
shall have reasonably determined based on evidence submitted by Borrower and reasonably satisfactory to Lender, that (i) the Project
is performing generally consistent with the proforma underwriting performed by Lender in connection with the closing of the Loan,
including without limitation satisfactory rental rates for the Project (which rental rates shall not be less than 96% of the proforma
rental rates) and satisfactory absorption rates (which shall not be less than 18 units per month) and (ii) the Project has maintained
a Debt Service Coverage Ratio greater than or equal to 1.00 to 1.00 for the ninety (90) day period leading up to the date on which
such disbursement would be made by Lender.

 

12.8         Special
Conditions for Vertical Construction.

 

Not
later than the commencement of vertical construction, Borrower shall have provided Lender with sufficient evidence that Borrower
has obtained builder's risk insurance in accordance with Exhibit E attached hereto. 

 

ARTICLE
13

FINAL DISBURSEMENT FOR CONSTRUCTION

 

13.1         Final
Disbursement for Construction.

 

Lender
will advance to Borrower the final disbursement for the cost of the Construction (including retainages) when the following conditions
have been complied with, provided that all other conditions in this Agreement for disbursements have been complied with:

 

(a)          The
Improvements have been fully completed and equipped substantially in accordance with the Plans and Specifications free and clear
of mechanics’ liens and security interests and are ready for occupancy;

 

(b)          Borrower
shall have furnished to Lender “all risks” casualty insurance in form and amount and with companies reasonably satisfactory
to Lender in accordance with the requirements contained herein, including without limitation the provision not later than the
date on which the Project’s first residential unit is ready for occupancy of “all risk” or “special form”
Property insurance, documented with form, terms, and conditions reasonably acceptable to Lender.

 

(c)          Borrower
shall have furnished to Lender copies of all licenses and permits required by any Governmental Authority having jurisdiction for
the occupancy of the Improvements and the operation thereof, including a certificate of occupancy from the municipality in which
the Project is located, or a letter from the appropriate Governmental Authority that no such certificate is issued;

 

(d)          [Reserved];

 

(e)          Borrower
shall have furnished (or shall furnish upon disbursement of the proceeds to the relevant vendors) an as-built survey covering
the completed Improvements in compliance with Section 8.1(c);

 

(f)           All
fixtures, furnishings, furniture, equipment and other property required for the operation of the Project shall have been installed
free and clear of all liens and security interests, except in favor of Lender;

 

    	- 31 -

    	 

    

 

(g)          Borrower
shall have furnished to Lender copies of all final waivers of lien and sworn statements from contractors, subcontractors and material
suppliers and an affidavit from the General Contractor in accordance with the mechanic’s lien law of the State or as otherwise
established by Lender; such final waivers shall indicate the amount remaining to be paid to such contractor, subcontractor or
supplier and shall confirm that such waiver is final provided such amount is received;

 

(h)          Borrower
shall have furnished to Lender a certificate from the Architect or other evidence satisfactory to Lender dated at or about the
Completion Date (as the same may be extended in accordance with Section 15.1(b) for Unavoidable Delay) stating that (i) the
Improvements have been completed in accordance with the Plans and Specifications, and (ii) the Improvements as so completed
comply with all applicable Laws;

 

(i)           Lender
shall have received a certificate from the Lender’s Consultant for the sole benefit of Lender that the Improvements have
been satisfactorily completed in accordance with the Plans and Specifications; and

 

(j)          Borrower
shall have entered into a property management agreement for the management, leasing and operation of the Project with a management
company. Such agreement and management company shall be approved by Lender, such approval not to be unreasonably withheld, conditioned
or delayed. Borrower represents and warrants to Lender that as of the date of this Agreement it has not entered into any such
agreement. Upon Lender’s request, Borrower shall execute a subordination agreement with respect to such management agreement
and shall cause the management company to join in such subordination agreement. Any such subordination agreement entered into
shall be deemed one of the “Loan Documents”.

 

If
Borrower fails to comply with and satisfy any of the final disbursement conditions contained in this Section 13.1
within sixty (60) days after the Completion Date (as the same may be extended in accordance with Section 15.1(b) for Unavoidable
Delay), such failure shall constitute an Event of Default hereunder.

 

ARTICLE
14

CERTAIN OTHER REQUIREMENTS

 

14.1         Deposit
Accounts.

 

Borrower covenants
and agrees that all operating and other deposit accounts of the Borrower shall be maintained with the Lender.

 

14.2         Limitation
on Management Fee.

 

Borrower covenants and agrees
that the management fees for the Project may not, in any 12-month period, exceed four percent (4%) of the Project’s Gross
Revenues for such period, without the Lender’s written consent.

 

    	- 32 -

    	 

    

 

ARTICLE
15

OTHER COVENANTS

 

15.1         Borrower
further covenants and agrees as follows:

 

(a)          Opening
of Loan on or Prior to Loan Opening Date. All conditions precedent to the Opening of the Loan shall be complied with on or
prior to May 14, 2014. If Borrower has not satisfied all conditions precedent to, and otherwise qualified for, the Opening of
the Loan by such date, Lender may at its sole option terminate Lender’s obligation to fund the Loan by written notice to
Borrower.

 

(b)          Construction
of Improvements. The Improvements shall be constructed and fully equipped in a good and workmanlike manner with materials
of high quality, strictly in accordance with the Plans and Specifications (or in accordance with any changes therein that may
be approved in writing by Lender or as to which Lender’s approval is not required), and such construction and equipping
will be commenced on or before the Construction Commencement Date and prosecuted with due diligence and continuity in accordance
with the Construction Schedule and fully completed not later than the Completion Date. The Completion Date shall be extended in
writing by Lender by the number of days resulting from any Unavoidable Delay in the Construction of the Project, (but under no
circumstances shall Lender be obligated to extend the Completion Date beyond the Maturity Date), provided that Lender shall not
be obligated to grant any such extension unless (i) Borrower gives notice of such delay to Lender promptly upon learning of the
event resulting in such delay and (ii) after giving effect to the consequences of such delay, the Loan shall remain “In
Balance”.

 

(c)          Changes
in Plans and Specifications. No changes will be made in the Plans and Specifications without the prior written approval of
Lender, such approval not to be unreasonably withheld or delayed; provided, however, that Borrower may make changes
to the Plans and Specifications (and enter into corresponding change orders to the General Contract) without Lender’s prior
written approval, if (i) Borrower notifies Lender in writing of such change within seven (7) days thereafter; (ii) Borrower
obtains the approval of all parties whose approval is required, including sureties, and any Governmental Authority to the extent
approval from such parties is required; (iii) the structural integrity of the Improvements is not impaired; (iv) no
material change in architectural appearance is effected; (v) the performance of the mechanical, electrical, and life safety
systems of the Improvements is not adversely affected; (vi) the cost of or reduction resulting from such change (x) does
not exceed One Hundred Thousand and No/100th Dollars ($100,000.00) and (y) when added to all other changes which
have not been approved in writing by Lender, the resulting aggregate cost or reduction does not exceed Two Hundred Fifty Thousand
and No/100th Dollars ($250,000.00). Changes in the scope of construction work or to any construction related contract
must be documented with a change order on the AIA Form G701 or equivalent form.

 

(d)          Inspection
by Lender. Borrower will cooperate with Lender in arranging for inspections by representatives of Lender of the progress of
the Construction from time to time including an examination of: (i) the Improvements; (ii) all materials to be used in the Construction;
(iii) all plans and shop drawings which are or may be kept at the construction site; (iv) any contracts, bills of sale, statements,
receipts or vouchers in connection with the Improvements; (v) all work done, labor performed, materials furnished in and about
the Improvements; (vi) all books, contracts and records with respect to the Improvements; and (vii) any other documents relating
to the Improvements or the Construction. Borrower shall reasonably cooperate with Lender’s Consultant to enable him to perform
his functions hereunder. Borrower shall, upon Lender’s or Lender’s Consultant’s reasonable request, correct
any defect in the Construction or any failure of the Construction to comply with the Plans and Specifications.

 

(e)          Mechanics’
Liens and Contest Thereof. Borrower will not suffer or permit any mechanics’ lien claims to be filed or otherwise asserted
against the Project or any funds due to the General Contractor, and will promptly discharge the same in case of the filing of
any claims for lien or proceedings for the enforcement thereof, provided, however, that Borrower shall have the
right to contest in good faith and with reasonable diligence the validity of any such lien or claim provided that Borrower posts
a statutory lien bond which removes such lien from title to the Project within thirty (30) days of written notice by Lender to
Borrower of the existence of the lien. Lender will not be required to make any further disbursements of the proceeds of the Loan
until any mechanics’ lien claims have been removed and Lender may, at its option, restrict disbursements to reserve sufficient
sums to pay one hundred fifty percent (150%) of the lien.

 

    	- 33 -

    	 

    

 

(f)           Settlement
of Mechanics’ Lien Claims. If Borrower shall fail promptly and in all instances no earlier than the thirty (30) day
period referred to in Section 15.1(e) above, either (i) to discharge any such lien; or (ii) post a statutory lien
bond in the manner provided in Section 15.1(e)  Lender may, at its election (but shall not be required to), procure
the release and discharge of any such claim and any judgment or decree thereon and, further, may in its sole discretion effect
any settlement or compromise of the same, or may furnish such security or indemnity to the Title Insurer, and any amounts so expended
by Lender, including premiums paid or security furnished in connection with the issuance of any surety company bonds, shall be
deemed to constitute disbursement of the proceeds of the Loan hereunder. In settling, compromising or discharging any claims for
lien, Lender shall not be required to inquire into the validity or amount of any such claim.

 

(g)          Renewal
of Insurance. Borrower shall cause insurance policies to be maintained in compliance with Exhibit E at all times, including
without limitation the provision not later than the date on which the Project’s first residential unit is ready for occupancy
of “all risk” or “special form” Property insurance, documented with form, terms, and conditions acceptable
to Lender. Borrower shall timely pay all premiums on all insurance policies required hereunder, and as and when additional insurance
is required, from time to time, during the progress of Construction, and as and when any policies of insurance may expire, furnish
to Lender, premiums prepaid, additional and renewal insurance policies with companies, coverage and in amounts satisfactory to
Lender in accordance with Section 8.1(d).

 

(h)          Payment
of Taxes. Borrower shall pay all real estate taxes and assessments and charges of every kind upon the Project before the same
become delinquent, provided, however, that Borrower shall have the right to pay such tax under protest or to otherwise contest
any such tax or assessment, but only if: (i) such contest has the effect of preventing the collection of such taxes so contested
and also of preventing the sale or forfeiture of the Project or any part thereof or any interest therein; (ii) Borrower has
notified Lender of Borrower’s intent to contest such taxes; and (iii) Borrower has deposited security in form and amount
reasonably satisfactory to Lender, and has increased the amount of such security so deposited promptly after Lender’s reasonable
request therefor. If Borrower fails to commence such contest or, having commenced to contest the same, and having deposited such
security required by Lender for its full amount, shall thereafter fail to prosecute such contest in good faith or with due diligence,
or, upon adverse conclusion of any such contest, shall fail to pay such tax, assessment or charge, Lender may, at its election
(but shall not be required to), pay and discharge any such tax, assessment or charge, and any interest or penalty thereon, and
any amounts so expended by Lender shall be deemed to constitute disbursements of the Loan proceeds hereunder (even if the total
amount of disbursements would exceed the face amount of the Note). Borrower shall furnish to Lender evidence that taxes are paid
at least five (5) days prior to the last date for payment of such taxes and before imposition of any penalty or accrual of interest.

 

(i)           Tax
and Insurance Escrow Accounts. Borrower shall, following the written request of Lender or upon the occurrence of any Event
of Default, make insurance and tax escrow deposits, in amounts reasonably determined by Lender from time to time as being needed
to pay taxes and insurance premiums when due, in an interest bearing escrow account held by Lender in Lender’s name and
under its sole dominion and control. All payments deposited in the escrow account, and all interest accruing thereon, are pledged
as additional collateral for the Loan. Notwithstanding Lender’s holding of the escrow account, nothing herein shall obligate
Lender to pay any insurance premiums or real property taxes with respect to any portion of the Project unless the Event of Default
has been cured to the satisfaction of Lender. If the Event of Default has been satisfactorily cured, Lender shall make available
to Borrower such funds as may be deposited in the escrow account from time to time for Borrower’s payment of insurance premiums
or real property taxes due with respect to the Project.

 

    	- 34 -

    	 

    

 

(j)           Personal
Property. All of Borrower’s personal property, fixtures, attachments and equipment delivered upon, attached to or used
in connection with the Construction or the operation of the Project shall always be located at the Project and shall be kept free
and clear of all liens, encumbrances and security interests other than the liens established under the Loan Documents.

 

(k)          Leasing
Restrictions. Borrower will not enter into any Leases for a term of more than fifteen (15) months and all such Leases shall
be on substantially the form approved by Lender without material modification. Borrower shall provide Lender with a copy of the
fully executed original of all Leases promptly following request by Lender. Without the prior written consent of Lender, which
shall not be unreasonably withheld, Borrower and Borrower’s agents shall not accept any rental payment more than sixty (60)
days in advance of its due date. Lender reserves the right to subordinate the Mortgage to any Lease.

 

(l)           Defaults
Under Leases. Borrower will not suffer or permit any breach or default to occur in any of Borrower’s obligations under
any of the Leases nor suffer or permit the same to terminate by reason of any failure of Borrower to meet any requirement of any
Lease including those with respect to any time limitation within which any of Borrower’s work is to be done or the space
is to be available for occupancy by the lessee.

 

(m)          Lender’s
Attorneys’ Fees for Enforcement of Agreement. In case of any default or Event of Default hereunder, Borrower (in addition
to Lender’s attorneys’ fees, if any, to be paid pursuant to Section 7.4) will pay Lender’s reasonable and
actual attorney’s fees at standard hourly rates without regard to any presumptive statutory attorney’s fees (including,
without limitation, any attorney and paralegal fees and costs incurred in connection with any litigation or bankruptcy or administrative
hearing and any appeals therefrom and any post-judgment enforcement action including, without limitation, supplementary proceedings)
in connection with the enforcement of this Agreement; without limiting the generality of the foregoing, if at any time or times
hereafter Lender employs counsel (whether or not any suit has been or shall be filed and whether or not other legal proceedings
have been or shall be instituted) for advice or other representation with respect to the Project, this Agreement, or any of the
other Loan Documents, or to protect, collect, lease, sell, take possession of, or liquidate any of the Project, or to attempt
to enforce any security interest or lien in any portion of the Project, or to enforce any rights of Lender or Borrower’s
obligations hereunder, then in any of such events all of the reasonable and actual attorney’s fees at standard hourly rates
without regard to any presumptive statutory attorney’s fees arising from such services, and any expenses, costs and charges
relating thereto (including fees and costs of paralegals), shall constitute an additional liability owing by Borrower to Lender,
payable on demand.

 

(n)          Appraisals.
Lender shall have the right to obtain a new or updated Appraisal of the Project from time to time. Borrower shall cooperate with
Lender in this regard. If the Appraisal is obtained to comply with this Agreement or any applicable law or regulatory requirement,
or bank policy promulgated to comply therewith, or if an Event of Default exists, Borrower shall pay for any such Appraisal upon
Lender’s request.

 

    	- 35 -

    	 

    

 

(o)          Furnishing
Information. Borrower shall deliver or cause to be delivered to Lender quarterly financial statements for Borrower within
forty-five (45) days after the end of each calendar quarter. Borrower shall deliver or cause to be delivered to Lender annual
financial statements for Borrower and Guarantors within ninety (90) days after the end of each calendar year, together with a
duly executed Certificate of Compliance in the form of Exhibit J attached hereto. All such financial statements shall be
in a format approved in writing by Lender in Lender’s reasonable sole discretion, internally prepared in accordance with
sound accounting principles consistently applied and presented in format consistent with the financial statements provided to
Lender in connection with the closing of the Loan and otherwise acceptable to Lender. Each financial statement shall be certified
as true, complete and correct in all material respects Borrower or, in the case of each of the Guarantors’ financial statements,
by the Guarantor to whom it relates. Upon request, Borrower shall deliver to Lender with respect to Borrower and Guarantor annual
Federal Income Tax Returns within ten (10) days after timely filing (for avoidance of doubt, any party may file extensions for
filing returns and shall still be considered a timely filing when thereafter filed in accordance with the extension). In addition,
prior to the Loan Opening and then not later than sixty (60) days before the end of each fiscal year of Borrower, Borrower shall
deliver to Lender the Project’s updated annual operating Budget for the following fiscal year. Following completion of Construction,
within fifteen (15) days following the end of each month, Borrower shall deliver to Lender: (i) monthly unaudited operating
cash flow statements for the Project, certified as true, complete and correct in all material respects by Borrower showing actual
sources and uses of cash during the preceding month; and (ii) a current rent roll and a summary of all leasing activity then
taking place with respect to the Project, particularly describing the status of all pending non-residential lease negotiations,
if any. Borrower and the Guarantor shall provide such additional unaudited financial information as Lender reasonably requires.
Borrower shall during regular business hours permit Lender or any of its agents or representatives to have access to and examine
all of its books and records regarding the development and operation of the Project.

 

(p)          Sign
and Publicity. Upon Lender’s request, at Lender’s sole cost, Borrower shall promptly erect a sign approved in
advance by Lender in a conspicuous location on the Project during the Construction indicating that the financing for the Project
is provided by Lender. Lender reserves the right to publicize the making of the Loan.

 

(q)          Lost
Note. Upon Lender’s furnishing to Borrower an affidavit to such effect, Borrower shall, if the Note is mutilated, destroyed,
lost or stolen, deliver to Lender, in substitution therefor, a new note containing the same terms and conditions as the Note,
properly notated to reflect the lost, destroyed, mutilated or stolen original note.

 

(r)           Indemnification.
Borrower shall indemnify Lender, including each party owning an interest in the Loan and their respective officers, directors,
employees and consultants (each, an “Indemnified Party”) and defend and hold each Indemnified Party harmless from
and against all claims, injury, damage, loss and liability, cost and expense (including reasonable and actual attorney’s
fees at standard hourly rates without regard to any presumptive statutory attorney’s fees, costs and expenses) of any and
every kind to any persons or property by reason of (i) the Construction; (ii) the operation or maintenance of the Project;
(iii) any breach of representation or warranty, default or Event of Default under this Agreement or any other Loan Document
or Related Document; or (iv) any other matter arising in connection with the Loan, Borrower, Guarantor, any Tenant or the Project.
No Indemnified Party shall be entitled to be indemnified against its own gross negligence or willful misconduct. The foregoing
indemnification shall survive repayment of the Loan and shall continue to benefit Lender following any assignment of the Loan
with respect to matters arising or accruing prior to such assignment.

 

(s)          No
Additional Debt. Except for the Loan, Borrower shall neither incur nor guarantee any indebtedness (whether personal or nonrecourse,
secured or unsecured) other than customary trade payables paid within sixty (60) days after they are incurred.

 

(t)           Compliance
With Laws. Borrower shall comply with all applicable requirements (including applicable Laws) of any Governmental Authority
having jurisdiction over Borrower or the Project.

 

(u)          Organizational
Documents; Single Purpose. Borrower shall not, without the reasonable prior written consent of Lender, permit or suffer (i)
a material amendment or modification of its organizational documents, (ii) the admission of any new member, partner or shareholder,
or (iii) any dissolution or termination of its existence. Borrower shall not, without the prior written consent of Lender, engage
in any business other than the ownership, development, leasing and operation of the Project.

 

    	- 36 -

    	 

    

 

(v)         Furnishing
Reports. Upon Lender’s reasonable request, Borrower shall provide Lender with copies of all inspections, reports, test
results and other information received by any Borrower, which in any way relate to the Project or any part thereof.

 

(w)          Management
Contracts. Borrower shall not enter into, modify, amend, terminate or cancel any management contracts for the Project or agreements
with agents or brokers, without the prior reasonable written approval of Lender, such approval not to be unreasonably withheld
or delayed.

 

(x)          Furnishing
Notices. Borrower shall provide Lender with copies of all material notices pertaining to the Project received by Borrower
from any Tenant, Governmental Authority or insurance company within ten (10) days after such notice is received by Borrower.

 

(y)          Construction
Contracts. Borrower shall not enter into, modify, amend, terminate or cancel any contracts for the Construction to which Borrower
is a party, without the prior written approval of Lender, which approval shall not be unreasonably withheld or delayed. Borrower
will furnish Lender promptly after execution thereof executed copies of all contracts between Borrower, architects, engineers
and contractors and all Subcontracts between the General Contractor or contractors and all of their subcontractors and suppliers,
which contracts and subcontracts may not have been furnished pursuant to Section 9.1(a) at the time of the Opening
of the Loan.

 

(z)          Correction
of Defects. Within five (5) days after Borrower acquires actual knowledge of or receives notice of a defect in the Improvements
or any departure in any material respects from the Plans and Specifications, or any other requirement of this Agreement, Borrower
will proceed with diligence to correct all such defects and departures.

 

(aa)         Hold
Disbursements in Trust. Borrower shall receive and hold in trust for the sole benefit of Lender (and not for the benefit of
any other person, including, but not limited to, contractors or any subcontractors) all advances made hereunder directly to Borrower,
for the purpose of paying costs of the Construction in accordance with the Budget. Borrower shall use the proceeds of the Loan
solely for the payment of costs as specified in the Budget. Borrower will pay all other costs, expenses and fees relating to the
acquisition, equipping, use and operation of the Project.

 

(bb)         Foundation
Survey. Not later than thirty (30) days after completion of all foundations with respect to the Improvements, Borrower shall
furnish to Lender a survey of the Land with such foundations of the Improvements located thereon, and also satisfying the requirements
set forth in Section 8.1(f).

 

(cc)         Alterations.
Subject to the terms of Section 15.1(c), without the prior written consent of Lender, Borrower shall not make any material alterations
to the Project (other than completion of the Construction in accordance with the Plans and Specifications as may be modified from
time to time in accordance with this Agreement).

 

(dd)         Cash
Distributions. Borrower shall not make any distributions to partners, members or shareholders, provided that after completion
of Construction and achievement of breakeven operations Borrower may so distribute Monthly Excess Cash Flow not needed to pay
Operating Expenses or amounts payable under the Loan Documents. For the avoidance of doubt, the payment of the Development Fee
in accordance with Section 15.1(ee) and the disbursement of the Cost Savings Disbursement in accordance with Section
12.7 shall not be a violation of this Section 15.1(dd).

 

    	- 37 -

    	 

    

 

(ee)         Payment
of Development Fee. Development Manager at all times shall be the developer of the Improvements and except for the Development
Agreement, Borrower shall not enter into any agreement by which Borrower engages another party to oversee the development of the
Improvements. Notwithstanding anything to the contrary contained in the Development Agreement, this Agreement, the other Loan
Documents, Borrower’s organizational documents or any other agreement, Borrower will not pay any developer fee, developer
overhead, developer profit or similar amount (collectively, “Development Fee”) except for a Development Fee not exceeding
One Million Fifty-Seven Thousand Eight Hundred Seven and No/100th Dollars ($1,057,807.00) may be paid to Development
Manager. The Development Fee shall be paid strictly in accordance with the amounts and upon the satisfaction of the conditions
and provisions of Section 11.1 of the Development Agreement. Borrower covenants and agrees that without the prior written consent
of Lender, which consent will not be unreasonably withheld, conditioned or delayed, (i) it will not modify, amend or supplement
the Development Agreement and (ii) the day-to-day administration and management of the development and construction of the Project
shall not cease to be performed by Development Manager pursuant to the Development Agreement.

 

(ff)         Partition
and Trust Agreement Distributions. Borrower shall not partition or permit the partitioning of the Project and
Borrower does hereby fully and irrevocably waive its right to partition the Project. Borrower shall
not make any distributions to any of the beneficiaries under the Trust Agreement, provided that after completion of Construction
and achievement of breakeven operations Borrower may so distribute Monthly Excess Cash Flow not needed to pay Operating Expenses
or amounts payable under the Loan Documents. For the avoidance of doubt, the payment of the Development Fee in accordance with
Section 15.1(ee) and the disbursement of the Cost Savings Disbursement in accordance with Section 12.7 shall not
be a violation of this Section 15.1(ff).

 

15.2       Authorized
Representative. 

 

Borrower
hereby appoints Rob Meyer and Mark Mechlowitz as its authorized representatives (together with any substitute authorized representative,
the “Authorized Representative”) for purposes of dealing with Lender on behalf of Borrower in respect of any and all
matters in connection with this Agreement, the other Loan Documents, and the Loan. The Authorized Representative shall have the
power, in his discretion, to give and receive all notices, monies, approvals, and other documents and instruments, and to take
any other action on behalf of Borrower. All actions by the Authorized Representative shall be final and binding on Borrower. Lender
may rely on the authority given to the Authorized Representative until actual receipt by Lender of a duly authorized resolution
substituting a different person as the Authorized Representative. No more than one person shall serve as Authorized Representative
at any given time.

 

ARTICLE
16

 

CASUALTIES
AND CONDEMNATION

 

16.1       Lender’s
Election to Apply Proceeds on Indebtedness.

 

(a)          Subject
to the provisions of Section 16.1(b) below, Lender may elect to collect, retain and apply upon the indebtedness of Borrower
under this Agreement or any of the other Loan Documents all proceeds of insurance or condemnation (individually and collectively
referred to as “Proceeds”) in excess of One Hundred Twenty-Five Thousand and No/100th Dollars ($125,000.00),
after deduction of all expenses of collection and settlement, including attorneys’ and adjusters’ fees and charges
(the “Threshold Amount”). Any proceeds remaining after repayment of the indebtedness under the Loan Documents
shall be paid by Lender to Borrower. If the Proceeds are not in excess of the Threshold Amount, then provided no Event of Default
has occurred and is continuing hereunder Lender shall make such Proceeds available to Borrower to be used solely towards reconstruction
of the Project (or if in connection with a condemnation no restoration is required, Borrower may use such Proceeds to pay Operating
Expenses and debt service on the Loan).

 

    	- 38 -

    	 

    

 

(b)          Notwithstanding
anything in Section 16.1(a) to the contrary, in the event of any casualty to the Improvements or any condemnation of part
of the Project, Lender agrees to make available the Proceeds to restoration of the Improvements if (i) no Event of Default
exists, (ii) all Proceeds are deposited with Lender, (iii) in Lender’s reasonable judgment, the amount of Proceeds
available for restoration of the Improvements (together with undisbursed proceeds of the Loan, if any, allocated for the cost
of the Construction and any sums or other security acceptable to Lender deposited with Lender by Borrower for such purpose) is
sufficient to pay the full and complete costs of such restoration, (iv)  if the cost of restoration exceeds ten percent (10%)
of the Loan Amount, in Lender’s reasonable determination after completion of restoration the Loan Amount will not exceed
75% of the fair market value of the Project, (v) in Lender’s reasonable determination, the Project can be restored
to an architecturally and economically viable project in compliance with applicable Laws, (vi) each Guarantor reaffirms its Completion
Guaranty in writing, and (vii) in Lender’s reasonable determination, such restoration is likely to be completed not later
than three months prior to the Maturity Date.

 

16.2       Borrower’s
Obligation to Rebuild and Use of Proceeds Therefor.

 

In
case Lender does not elect to apply or does not have the right to apply the Proceeds to the indebtedness, as provided in Section
16.1 above, Borrower shall:

 

(a)          Proceed
with diligence to make settlement with insurers or the appropriate Governmental Authorities and cause the Proceeds to be deposited
with Lender;

 

(b)          In
the event of any material delay in making settlement with insurers or the appropriate Governmental Authorities or effecting collection
of the Proceeds, deposit with Lender the full amount required to complete construction as aforesaid;

 

(c)          In
the event the Proceeds and the available proceeds of the Loan are insufficient to assure the Lender that the Loan will be In Balance,
promptly deposit with Lender any amount necessary to place the Loan In Balance (following which Lender will make disbursements
of available proceeds of the Loan to Borrower for restoration provided that Borrower has satisfied and complies with all conditions
precedent under this Agreement for an advance of the Loan); and

 

(d)          Promptly
proceed with the assumption of Construction of the Improvements, including the repair of all damage resulting from such fire,
condemnation or other cause and restoration to its former condition.

 

Any
request by Borrower for a disbursement by Lender of Proceeds and funds deposited by Borrower shall be treated by Lender as if
such request were for an advance of the Loan hereunder, and the disbursement thereof shall be conditioned upon Borrower’s
compliance with and satisfaction of the same conditions precedent as would be applicable under this Agreement for an advance of
the Loan. For avoidance of doubt, disbursements made from such funds shall not be deemed an advancement of principal under the
Loan.

 

ARTICLE
17

ASSIGNMENTS BY LENDER AND BORROWER

 

17.1       Assignments
and Participations.

 

Lender
may from time to time sell the Loan and the Loan Documents (or any interest therein) and may grant participations in the Loan;
provided, however, that prior to completion of Construction Lender will continue to service the Loan and Borrower shall not be
required to make payments due under the Loan to more than one party at a time. Borrower agrees to cooperate with Lender’s
efforts to do any of the foregoing and to execute all documents reasonably required by Lender in connection therewith which do
not materially adversely affect Borrower’s rights under the Loan Documents.

 

    	- 39 -

    	 

    

 

17.2       Prohibition
of Assignments and Transfers by Borrower.

 

Borrower
shall not assign or attempt to assign its rights under this Agreement and any purported assignment shall be void. Without the
prior written consent of Lender, in Lender’s sole discretion, Borrower shall not suffer or permit (a) any change in the
management (whether direct or indirect) of the Project or of Borrower, or (b) any Transfer.

 

Notwithstanding
the foregoing to the contrary, provided the OFAC Compliance Condition and Control Condition (and any other conditions set forth
in (a) through (g) below) are satisfied and complied with, the following Transfers shall be permitted without Lender’s prior
written consent:

 

(a)          a
Transfer by devise or descent or by operation of law upon the death of an individual member, partner or shareholder of any Person
that is a direct or indirect legal or beneficial owner of Borrower where such Transfer does not result in an Event of Default;

 

(b)          the
Transfer of up to forty-nine and nine-tenths percent (49.9%) in the aggregate of the membership percentage interests in BR/CDP
UCFP Venture, LLC (“BR/CDP Venture”);

 

(c)          a
Transfer of interests by and among the existing members of CDP UCFP Developer, LLC (“Catalyst Member”) or Catalyst
Development Partners II, LLC;

 

(d)          a
Transfer of the membership interests in BR/CDP Venture by BR Member to Catalyst Member;

 

(e)          a
Transfer of interests in BR Member by the existing members of BR Orlando UCFP, LLC (the “BR Member”) to Affiliates
of BR Member, and further provided after such Transfer (i) Bluerock Special Opportunity + Income Fund, LLC (“BR SOIF”)
(or following the Transfer described in subsection (f) below, BR REIT, BR Operating Partnership or one of their Affiliates) shall
continue to own a majority common membership interest in, and to Control, BR Member; and (ii) BR Member continues to be a member
of BR/CDP Venture;

 

(f)          a
Transfer of interests in BR Member by (1) the admission of Bluerock Residential Growth REIT, Inc (“BR REIT”), Bluerock
Residential Holdings, LP (“Bluerock Operating Partnership”) (or an Affiliate directly or indirectly owned and controlled
by BR REIT or BR Operating Partnership) as a preferred equity member of BR Member holding typical preferred equity rights in BR
Member as the owners of BR Member approve, including but not limited to, the right to a preferred return with respect to the other
members of BR Member, consent rights over certain major decisions of BR Member, additional management control over BR Member in
the event of a default under the preferred equity terms, and the right to dilute the ownership and other rights of the other members
of BR Member in connection with any failure to comply with the preferred equity terms (and the associated modification of the
limited liability company agreement of BR Member in order to reflect such terms) and (2) the conversion of such preferred equity
membership interest, anticipated to occur on or before the stabilization of the Project, into a majority common membership interest
in, and management control over, BR Member by the preferred equity party (and the associated modification of the limited liability
company agreement of BR Member to reflect such terms), provided after such Transfer (i) Lender receives written notice of, and
an organizational chart reflecting, the new structure; (ii) BR Member continues to be a member of BR/CDP Venture; and (iii) the
parties exercising Control of BR/CDP Venture and of the Borrower, including without limitation Guarantor Principals, continue
to Control, directly or indirectly, BR/CDP Venture and the Borrower in the manner in which they did on the date of the Loan Opening;
and

 

    	- 40 -

    	 

    

 

(g)          a
Transfer of non-controlling membership interests or partnership interests in any direct or indirect owner of the BR Member, including
BR SOIF and, following a Transfer pursuant to subsection (f) above, BR REIT and/or BR Operating Partnership (or an Affiliate directly
or indirectly owned or controlled by BR REIT or BR Operating Partnership (the “Affected Entity”), provided after such
Transfer (i) the Affected Entity continues to be Controlled by the same Person or Persons that Controlled the Affected Entity
prior to such Transfers; (ii) BR Member continues to be a member of BR/CDP Venture; and (iii) the parties exercising Control of
BR/CDP Venture and of the Borrower, including without limitation Guarantor Principals, continue to Control, directly or indirectly,
BR/CDP Venture and the Borrower in the manner in which they did on the date of the Loan Opening.

 

Notwithstanding
the foregoing to the contrary, Lender shall permit a Transfer of membership interests in BR/CDP Venture by Catalyst Member to
BR Member pursuant to the buy/sell provisions in the Venture Agreement (including, without limitation, any right to acquire the
interests of El Dorado, LLC or Spyglass Hill, LLC, as Co-Tenants, as part of a so-called “drag along,” pursuant to
the TIC Agreement) (a “Venture Control Transfer”) that results in Catalyst Member no longer being the Manager of the
Venture and the Guarantor Principals no longer being in Control, directly or indirectly, of BR/CDP Venture and the Borrower in
the manner in which they did on the date of the Loan Opening provided all of the following conditions are satisfied:

 

(A)         BR
Member shall have certified in writing to Lender that BR Member has duly exercised its rights, powers and authorities in compliance
with the terms of the Venture Agreement in effect on the date hereof;

 

(B)         Lender
shall have determined, in its reasonable judgment, that the individuals that are directly responsible for the management of BR/CDP
Venture possess adequate capacity and experience to supervise and manage the Construction (if Construction of the Improvements
is not complete) and the operation, marketing and leasing of the Project, and to otherwise cause Borrower to perform and observe
its obligations under this Agreement and the other Loan Documents;

 

(C)         BR
Member shall have caused an additional guarantor or guarantors (whether one or more, the “Additional Guarantor”) acceptable
to Lender, in its reasonable discretion, to provide a replacement environmental indemnity agreement, completion guaranty and payment
guaranty, in each case substantially in form and content identical to the Environmental Indemnity, Completion Guaranty and Payment
Guaranty, respectively, and all other documentation reasonably required by Lender, and prior written approval of the Additional
Guarantor and said documentation is a condition of the Additional Guarantor being an approved Additional Guarantor. Approval of
an Additional Guarantor is subject to Lender's receipt within thirty (30) days prior to such Transfer of information satisfactory
to Lender in its sole but reasonable discretion identifying the proposed guarantor and its financial structure, and such other
information regarding the proposed guarantor as Lender may request in its reasonable discretion. Lender's approval of the Additional
Guarantor may be based upon, among other things, (i) satisfaction of Lender's financial requirements set forth in the existing
Payment Guaranty and Completion Guaranty (including without limitation evidence that Additional Guarantor complies with and will
be able to comply with the financial covenants set forth therein), (ii) “know your customer” and other regulatory
requirements, and (iii) the Borrower, any continuing Guarantor and Additional Guarantor's reaffirmation of their obligations under
the Loan Documents following the addition of the Additional Guarantor and confirmation that no novation or release of Borrower
or any other Guarantor has occurred. Following the addition of an Additional Guarantor pursuant to the terms hereof, the Additional
Guarantor shall constitute a “Guarantor” for all purposes under the Loan Documents. Notwithstanding anything to the
contrary contained herein, in no event will a Venture Control Transfer, including without limitation Lender’s acceptance
of an Additional Guarantor, be deemed in any way to constitute an agreement by Lender to release any other Guarantor with respect
to its obligations under the Loan Documents, whether or not such other Guarantor reaffirms such obligations.

 

    	- 41 -

    	 

    

 

(D)         the
OFAC Compliance Condition is satisfied;

 

(E)         if
such Transfer occurs prior to completion of Construction of the Improvements in accordance with the terms of this Agreement and
such Transfer results in the termination or cancellation of the Development Agreement, (i) Borrower shall have retained, within
ten (10) days after the effective date of such Transfer, a third party construction manager approved by Lender (pursuant to a
contract approved by Lender) to manage and supervise the completion of Construction of the Improvements (unless Lender shall have
determined, in its reasonable judgment, that the individuals that are directly responsible for the management of Borrower possess
adequate capacity and experience necessary to supervise and manage the Construction of the Improvements without the assistance
of a third-party approved construction manager); and (ii) if such Transfer results in the termination or cancellation of the General
Contract, (A) Borrower shall have entered into a new general construction contract for the Construction of the Improvements within
thirty (30) days after the effective date of such termination or cancellation of the General Contract, (B) Lender shall have approved,
in its reasonable judgment, the new general contractor and the terms and conditions of the new general construction contract and
(C) the Loan remains “In Balance” in accordance with the provisions described in Section 11.1 of the Loan Agreement;

 

(F)         if
such Transfer results in the termination or cancellation of any management contract for the Project, Borrower shall have retained,
within ten (10) days after the effective date of such termination or cancellation, a third party property manager acceptable to
Lender pursuant to a contract approved by Lender to manage, lease and operate the Project;

 

(G)         if
any Event of Default exists at the time of such Transfer, or any event which would be a monetary Event of Default or a material
non-monetary Event of Default following notice and/or the passage of time, exists under the Loan Documents, Borrower shall have
cured same to the satisfaction of Lender (provided that the Lender shall have no obligation to allow Borrower to cure any Event
of Default) [further provided, however, that in no event shall Lender be deemed to have waived any Event of Default, whether material
or not, and Borrower shall diligently and continuously act to cure any such Event of Default not later than the end of any notice
and cure period applicable thereto];

 

(H)         Borrower
and Additional Guarantor shall have furnished to Lender such additional certificates, instruments and other documents as Lender
or its counsel might reasonably request to evidence the organization, existence and authority of Additional Guarantor, including,
without limitation, an opinion of counsel in form and substance reasonably satisfactory to Lender; and

 

(I)         BR
Member or Borrower shall have paid to Lender an administrative fee of $15,000.00 and all reasonable costs and expenses incurred
by Lender in connection with such Transfer, including without limitation reasonable attorney’s fees actually incurred.

 

The
“OFAC Compliance Condition” shall be deemed to be satisfied if (i) the representation and warranty contained in Section
3.1(w) remains true and correct in all material respects following such Transfer and (ii) in the instance of any Transfer
in which any Person will hold, either directly or indirectly, a twenty-five percent (25%) or greater ownership interest in Borrower,
Lender has received such information about such Person as Lender deems reasonably necessary to ensure compliance with all applicable
Laws concerning money laundering and similar activities following such Transfer.

 

The
“Control Condition” shall be deemed to be satisfied if (i) Robert S. Fishel, Mark Mechlowitz, Robert G. Meyer, and
Jorge L. Sardinas (individually, a “Guarantor Principal,” and collectively, the “Guarantor Principals”)
shall each continue to own, directly or indirectly, an ownership interest in BR/CDP Venture; (ii) Guarantor Principals shall continue
to Control, directly or indirectly, BR/CDP Venture and the Borrower in the manner in which they did on the date of the Loan Opening;
and (iii) the day-to-day administration and management of the development and construction of the Project continue to be performed
by Development Manager pursuant to the Development Agreement.

 

    	- 42 -

    	 

    

 

17.3       Prohibition
of Transfers in Violation of ERISA.

 

In
addition to the prohibitions set forth in Section 17.2 above, Borrower shall not assign, sell, pledge, encumber, transfer,
hypothecate or otherwise dispose of its interest or rights in this Agreement or in the Project, or attempt to do any of the foregoing
or suffer any of the foregoing, nor shall any party owning a direct or indirect interest in Borrower assign, sell, pledge, mortgage,
encumber, transfer, hypothecate or otherwise dispose of any of its rights or interest (direct or indirect) in Borrower, attempt
to do any of the foregoing or suffer any of the foregoing, if such action would cause the Loan, or the exercise of any of Lender’s
rights in connection therewith, to constitute a prohibited transaction under ERISA or the Internal Revenue Code or otherwise result
in Lender being deemed in violation of any applicable provision of ERISA. Borrower agrees to indemnify and hold Lender free and
harmless from and against all losses, costs (including attorneys’ fees and expenses), taxes, damages (including consequential
damages) and expenses Lender may suffer by reason of the investigation, defense and settlement of claims and in obtaining any
prohibited transaction exemption under ERISA necessary or desirable in Lender’s sole judgment or by reason of a breach of
the foregoing prohibitions. The foregoing indemnification shall be a recourse obligation of Borrower and shall survive repayment
of the Note, notwithstanding any limitations on recourse contained herein or in any of the Loan Documents.

 

17.4       Successors
and Assigns.

 

Subject
to the foregoing restrictions on transfer and assignment contained in this Article 17, this Agreement shall inure
to the benefit of and shall be binding on the parties hereto and their respective successors and permitted assigns.

 

ARTICLE
18

TIME OF THE ESSENCE

 

18.1       Time
is of the Essence. Borrower agrees that time is of the essence under this Agreement.

 

ARTICLE
19

EVENTS OF DEFAULT

 

The
occurrence of any one or more of the following shall constitute an “Event of Default” as said term is used herein:

 

(a)          Failure
of Borrower (i) (A) to make any principal payment within five (5) days after the date when due, (B) to pay any
interest within five (5) days after the date when due or (C) to observe or perform any of the other covenants or conditions
by Borrower to be performed under the terms of this Agreement or any other Loan Document concerning the payment of money, for
a period of ten (10) days after written notice from Lender that the same is due and payable; or (ii) for a period of thirty
(30) days after written notice from Lender, to observe or perform any non-monetary covenant or condition contained in this Agreement
or any other Loan Documents; provided that if any such failure concerning a non-monetary covenant or condition is susceptible
to cure and cannot reasonably be cured within said thirty (30) day period, then Borrower shall have an additional ninety
(90) day period to cure such failure and no Event of Default shall be deemed to exist hereunder so long as Borrower commences
such cure within the initial thirty (30) day period and diligently and in good faith pursues such cure to completion within
such resulting one hundred twenty (120) day period from the date of Lender’s notice; and provided further that if a different
notice or grace period is specified under any other subsection of this Section 19.1 with respect to a particular breach,
or if another subsection of this Section 19.1 applies to a particular breach and does not expressly provide for a notice
or grace period the specific provision shall control.

 

    	- 43 -

    	 

    

 

(b)          The
disapproval by Lender or Lender’s Consultant at any time of any construction work because of any defect in the Construction,
the failure of the Construction to comply with the Plans and Specifications or governmental approvals and failure of Borrower
to cause the same to be corrected to the reasonable satisfaction of Lender within the cure period provided in Section 19.1(a)(ii)
above.

 

(c)          A
delay in the Construction or a discontinuance for a period of fifteen (15) days after written notice from Lender concerning such
delay or discontinuance (other than Unavoidable Delays), or in any event a delay in the Construction so that the same is not,
in Lender’s reasonable judgment (giving due consideration to the reasonable assessment of Lender’s Consultant), likely
to be completed on or before the Completion Date.

 

(d)          The
bankruptcy or insolvency of the General Contractor and failure of Borrower to procure a contract with a new contractor satisfactory
to Lender within sixty (60) days from the occurrence of such bankruptcy or insolvency.

 

(e)          Any
Transfer or other event in violation of Sections 17.2 or 17.3.

 

(f)          The
death or incapacity of any Guarantor that is an individual; or

 

(g)          If
any warranty, representation, statement, report or certificate made now or hereafter by Borrower or any Guarantor is untrue or
incorrect in any material respect at the time made or delivered, provided that if such breach is reasonably susceptible of cure,
then no Event of Default shall exist so long as Borrower cures said breach (i) within the notice and cure period provided
in (a)(i)(C) above for a breach that can be cured by the payment of money or (ii) within the notice and cure period
provided in (a)(ii) above for any other breach.

 

(h)          Borrower
or any Guarantor shall commence a voluntary case concerning Borrower or such Guarantor under the Bankruptcy Code; or an involuntary
proceeding is commenced against Borrower or any Guarantor under the Bankruptcy Code (by any party other than Lender) and relief
is ordered against Borrower or such Guarantor, or the petition is controverted but not dismissed or stayed within ninety (90)
days after the commencement of the case, or a custodian (as defined in the Bankruptcy Code) is appointed for or takes charge of
all or substantially all of the property of Borrower or any Guarantor; or the Borrower or any Guarantor commences any other proceedings
under any reorganization, arrangement, readjustment of debt, relief of debtors, dissolution, insolvency or liquidation or similar
Law of any jurisdiction whether now or hereafter in effect relating to the Borrower or any Guarantor; or there is commenced against
Borrower or any Guarantor any such proceeding which remains undismissed or unstayed for a period of ninety (90) days; or the Borrower
or any Guarantor fails to controvert in a timely manner any such case under the Bankruptcy Code or any such proceeding, or any
order of relief or other order approving any such case or proceeding is entered; or the Borrower or any Guarantor by any act or
failure to act indicates its consent to, approval of, or acquiescence in any such case or proceeding or the appointment of any
custodian or the like of or for it for any substantial part of its property or suffers any such appointment to continue undischarged
or unstayed for a period of ninety (90) days.

 

(i)          Borrower
or any Guarantor shall make an assignment for the benefit of creditors, or shall admit in writing its inability to pay its debts
generally as they become due, or shall consent to the appointment of a receiver or trustee or liquidator of all of its property
or the major part thereof or if all or a substantial part of the assets of Borrower or any Guarantor are attached, seized, subjected
to a writ or distress warrant, or are levied upon, or come into the possession of any receiver, trustee, custodian or assignee
for the benefit of creditors.

 

    	- 44 -

    	 

    

 

(j)          If
Borrower is enjoined, restrained or in any way prevented by any court order from constructing or operating the Project, and Construction
or operations are delayed or discontinued for a period of thirty (30) days (subject to a period of Unavoidable Delay not in excess
of one hundred twenty [120] days).

 

(k)          Failure
by Borrower to make any Deficiency Deposit with Lender within the time and in the manner required by Article 11 hereof.

 

(l)          One
or more final, unappealable judgments are entered (i) against Borrower in amounts aggregating in excess of One Hundred Fifty Thousand
and No/100th Dollars ($150,000.00) or (ii) against any Guarantor in amounts aggregating in excess of Three Hundred
Fifty Thousand and No/100th Dollars ($350,000.00), and said judgments are not stayed or bonded over within thirty (30)
days after entry.

 

(m)          If
Borrower or any Guarantor shall fail to pay any debt owed by it or is in default under any agreement with Lender or any other
party (other than a failure or default for which Borrower’s maximum liability does not exceed One Hundred Fifty Thousand
and No/100th Dollars [$150,000.00] and Guarantor’s maximum liability does not exceed Three Hundred Fifty Thousand
and No/100th Dollars [$350,000.00]) and such failure or default continues after any applicable grace period specified
in the instrument or agreement relating thereto.

 

(n)          If
a Material Adverse Change occurs with respect to Borrower, the Project or any Guarantor.

 

(o)          The
occurrence of any other event or circumstance denominated as an Event of Default in this Agreement or under any of the other Loan
Documents and the expiration of any applicable grace or cure periods, if any, specified for such Event of Default herein or therein,
as the case may be.

 

In
the event any default is or shall be deemed to have occurred as a result of any event with respect to any Guarantor, Borrower
may cure such default by causing a substitute guarantor or substitute guarantors (whether one or more, the “Substitute Guarantor”)
acceptable to Lender, in its reasonable discretion, to provide within thirty (30) days after written notice of such default from
Lender, a replacement payment guaranty, completion guaranty, environmental indemnity agreement and all other documentation reasonably
required by Lender, and approval by Lender of the Substitute Guarantor and said documentation is a condition of the substitution
being an approved substitution. Approval of a Substitute Guarantor is subject to Lender's receipt within thirty (30) days prior
to such substitution of information satisfactory to Lender in its sole but reasonable discretion identifying the proposed guarantor
and its financial structure, and such other information regarding the proposed guarantor as Lender may request in its reasonable
discretion. Lender's approval of the Substitute Guarantor may be based upon, among other things, (i) satisfaction of Lender's
financial requirements set forth in the existing Payment Guaranty and Completion Guaranty (including without limitation evidence
that Substitute Guarantor complies with and will be able to comply with the financial covenants set forth therein); (ii) “know
your customer” and other regulatory requirements, (iii) Lender’s confirmation that (A) the representation and warranty
contained in Section 3.1(w) remains true and correct in all material respects following such substitution and (B) in the
instance of any substitution in which any Person will hold, either directly or indirectly, a twenty-five percent (25%) or greater
ownership interest in such Substitute Guarantor, Lender has received such information about such Person as Lender deems reasonably
necessary to ensure compliance with all applicable Laws concerning money laundering and similar activities following such substitution;
(iv) the Substitute Guarantor's execution and delivery of a replacement payment guaranty, completion guaranty and environmental
indemnity agreement in substantially similar format to the Payment Guaranty, the Completion Guaranty and the Environmental Indemnity;
and (v) the Borrower, any continuing Guarantor and Substitute Guarantor's reaffirmation of their obligations under the Loan Documents
following the addition of the Substitute Guarantor and confirmation that the addition of Substitute Guarantor and removal and
release of any other Guarantor by Lender shall not result in a novation or the release of Borrower or any other Guarantor. Following
the addition of a Substitute Guarantor pursuant to the terms hereof, the Substitute Guarantor shall constitute a “Guarantor”
for all purposes under the Loan Documents.

 

    	- 45 -

    	 

    

 

ARTICLE
20

LENDER’S REMEDIES IN EVENT OF DEFAULT

 

20.1       Remedies
Conferred Upon Lender.

 

Upon
the occurrence of any Event of Default, Lender may pursue any one or more of the following remedies concurrently or successively,
it being the intent hereof that none of such remedies shall be to the exclusion of any other:

 

(a)          Take
possession of the Project and complete the Construction and do anything which is necessary or appropriate in its sole judgment
to fulfill the obligations of Borrower under this Agreement and the other Loan Documents, including either the right to avail
itself of and procure performance of existing contracts or let any contracts with the same contractors or others. Without restricting
the generality of the foregoing and for the purposes aforesaid, Borrower hereby appoints and constitutes Lender its lawful attorney-in-fact
with full power of substitution in the Project to complete the Construction in the name of Borrower; to use unadvanced funds remaining
under the Note or which may be reserved, escrowed or set aside for any purposes hereunder at any time, or to advance funds in
excess of the face amount of the Note, to complete the Construction; to make changes in the Plans and Specifications which shall
be necessary or desirable to complete the Construction in substantially the manner contemplated by the Plans and Specifications;
to retain or employ new general contractors, subcontractors, architects, engineers and inspectors as shall be required for said
purposes; to pay, settle or compromise all existing bills and claims, which may be liens or security interests, or to avoid such
bills and claims becoming liens against the Project; to execute all applications and certificates in the name of Borrower prosecute
and defend all actions or proceedings in connection with the Improvements or Project; and to do any and every act which the Borrower
might do in its own behalf; it being understood and agreed that this power of attorney shall be a power coupled with an interest
and cannot be revoked;

 

(b)          Withhold
further disbursement of the proceeds of the Loan and/or terminate Lender’s obligations to make further disbursements hereunder;

 

(c)          Declare
the Note to be immediately due and payable;

 

(d)          Use
and apply any monies or letters of credit deposited by Borrower with Lender, regardless of the purposes for which the same was
deposited, to cure any such default or to apply on account of any indebtedness under this Agreement which is due and owing to
Lender; and

 

(e)          Exercise
or pursue any other remedy or cause of action permitted under this Agreement or any other Loan Documents, or conferred upon Lender
by operation of Law.

 

Notwithstanding
the foregoing, upon the occurrence of any Event of Default under Section 19.1(h) with respect to Borrower, all amounts
evidenced by the Note shall automatically become due and payable, without any presentment, demand, protest or notice of any kind
to Borrower.

 

    	- 46 -

    	 

    

 

ARTICLE
21

GENERAL PROVISIONS

 

21.1       Captions.

 

The
captions and headings of various Articles, Sections and subsections of this Agreement and Exhibits pertaining hereto are for convenience
only and are not to be considered as defining or limiting in any way the scope or intent of the provisions hereof.

 

21.2       Modification;
Waiver.

 

No
modification, waiver, amendment or discharge of this Agreement or any other Loan Document shall be valid unless the same is in
writing and signed by the party against which the enforcement of such modification, waiver, amendment or discharge is sought.

 

21.3       Governing
Law.

 

Irrespective
of the place of execution and/or delivery, this Agreement shall be governed by, and shall be construed in accordance with, the
laws of the State of Georgia.

 

21.4       Acquiescence
Not to Constitute Waiver of Lender’s Requirements.

 

Each
and every covenant and condition for the benefit of Lender contained in this Agreement may be waived by Lender, provided, however,
that to the extent that Lender may have acquiesced in any noncompliance with any construction or nonconstruction conditions precedent
to the Opening of the Loan or to any subsequent disbursement of Loan proceeds, such acquiescence shall not be deemed to constitute
a waiver by Lender of such requirements with respect to any future disbursements of Loan proceeds.

 

21.5       Disclaimer
by Lender.

 

This
Agreement is made for the sole benefit of Borrower and Lender, and no other person or persons shall have any benefits, rights
or remedies under or by reason of this Agreement, or by reason of any actions taken by Lender pursuant to this Agreement. Lender
shall not be liable to any contractors, subcontractors, supplier, architect, engineer, tenant or other party for labor or services
performed or materials supplied in connection with the Construction. Lender shall not be liable for any debts or claims accruing
in favor of any such parties against Borrower or others or against the Project. Lender, by making the Loan or taking any action
pursuant to any of the Loan Documents, shall not be deemed a partner or a joint venturer with Borrower or fiduciary of Borrower.
No payment of funds directly to a contractor or subcontractor or provider of services shall be deemed to create any third-party
beneficiary status or recognition of same by the Lender. Without limiting the generality of the foregoing:

 

(a)          Lender
shall have no liability, obligation or responsibility whatsoever with respect to the Construction. Any inspections of the Construction
made by or through Lender are for purposes of administration of the Loan only and neither Borrower nor any third party is entitled
to rely upon the same with respect to the quality, adequacy or suitability of materials or workmanship, conformity to the Plans
and Specifications, state of completion or otherwise;

 

(b)          Lender
neither undertakes nor assumes any responsibility or duty to Borrower to select, review, inspect, supervise, pass judgment upon
or inform Borrower of any matter in connection with the Project, including matters relating to the quality, adequacy or suitability
of: (i) the Plans and Specifications, (ii) architects, contractors, subcontractors and material suppliers employed or
utilized in connection with the Construction, or the workmanship of or the materials used by any of them, or (iii) the progress
or course of Construction and its conformity or nonconformity with the Plans and Specifications; Borrower shall rely entirely
upon its own judgment with respect to such matters, and any review, inspection, supervision, exercise of judgment or supply of
information to Borrower by Lender in connection with such matters is for the protection of Lender only, and neither Borrower nor
any third party is entitled to rely thereon; and

 

    	- 47 -

    	 

    

 

(c)          Lender
owes no duty of care to protect Borrower, Guarantor, or any Tenant against negligent, faulty, inadequate or defective building
or construction.

 

21.6     Partial
Invalidity; Severability.

 

If
any of the provisions of this Agreement, or the application thereof to any person, party or circumstances, shall, to any extent,
be invalid or unenforceable, the remainder of this Agreement, or the application of such provision or provisions to persons, parties
or circumstances other than those as to whom or which it is held invalid or unenforceable, shall not be affected thereby, and
every provision of this Agreement shall be valid and enforceable to the fullest extent permitted by law.

 

21.7       Definitions
Include Amendments.

 

Definitions
contained in this Agreement which identify documents, including, but not limited to, the Loan Documents, shall be deemed to include
all amendments and supplements to such documents from the date hereof, and all future amendments, modifications, and supplements
thereto entered into from time to time to satisfy the requirements of this Agreement or otherwise with the consent of Lender.
Reference to this Agreement contained in any of the foregoing documents shall be deemed to include all amendments and supplements
to this Agreement.

 

21.8       Execution
in Counterparts.

 

This
Agreement may be executed in any number of counterparts and by different parties hereto in separate counterparts, each of which
when so executed shall be deemed to be an original and all of which taken together shall constitute one and the same agreement.

 

21.9       Entire
Agreement.

 

This
Agreement, taken together with all of the other Loan Documents and all certificates and other documents delivered by Borrower
to Lender, embody the entire agreement and supersede all prior agreements, written or oral, relating to the subject matter hereof.

 

21.10     Waiver
of Damages.

 

In
no event shall Lender be liable to Borrower for punitive, exemplary or consequential damages, including, without limitation, lost
profits, whatever the nature of a breach by Lender of its obligations under this Agreement or any of the Loan Documents, and Borrower
for itself and its Guarantors waive all claims for punitive, exemplary or consequential damages.

 

21.11     Claims
Against Lender.

 

Lender
shall not be in default under this Agreement, or under any other Loan Documents, unless a written notice specifically setting
forth the claim of Borrower shall have been given to Lender within three (3) months after Borrower first had knowledge of the
occurrence of the event which Borrower alleges gave rise to such claim and Lender does not remedy or cure the default, if any
there be, promptly thereafter. Borrower waives any claim, set-off or defense against Lender arising by reason of any alleged default
by Lender as to which Borrower does not give such notice timely as aforesaid. Borrower acknowledges that such waiver is or may
be essential to Lender’s ability to enforce its remedies without delay and that such waiver therefore constitutes a substantial
part of the bargain between Lender and Borrower with regard to the Loan. No Guarantor or Tenant is intended to have any rights
as a third-party beneficiary of the provisions of this Section 21.11.

 

    	- 48 -

    	 

    

 

21.12     Jurisdiction.

 

TO
THE GREATEST EXTENT PERMITTED BY LAW, BORROWER HEREBY WAIVES ANY AND ALL RIGHTS TO REQUIRE MARSHALLING OF ASSETS BY LENDER. WITH
RESPECT TO ANY SUIT, ACTION OR PROCEEDINGS RELATING TO THIS AGREEMENT (EACH, A “PROCEEDING”), BORROWER IRREVOCABLY
(A) SUBMITS TO THE NON-EXCLUSIVE JURISDICTION OF THE STATE AND FEDERAL COURTS HAVING JURISDICTION IN THE CITY OF ATLANTA, COUNTY
OF FULTON AND STATE OF GEORGIA, AND (B) WAIVES ANY OBJECTION WHICH IT MAY HAVE AT ANY TIME TO THE LAYING OF VENUE OF ANY PROCEEDING
BROUGHT IN ANY SUCH COURT, WAIVES ANY CLAIM THAT ANY PROCEEDING HAS BEEN BROUGHT IN AN INCONVENIENT FORUM AND FURTHER WAIVES THE
RIGHT TO OBJECT, WITH RESPECT TO SUCH PROCEEDING, THAT SUCH COURT DOES NOT HAVE JURISDICTION OVER SUCH PARTY. NOTHING IN THIS
AGREEMENT SHALL PRECLUDE LENDER FROM BRINGING A PROCEEDING IN ANY OTHER JURISDICTION NOR WILL THE BRINGING OF A PROCEEDING IN
ANY ONE OR MORE JURISDICTIONS PRECLUDE THE BRINGING OF A PROCEEDING IN ANY OTHER JURISDICTION. BORROWER FURTHER AGREES AND CONSENTS
THAT, IN ADDITION TO ANY METHODS OF SERVICE OF PROCESS PROVIDED FOR UNDER APPLICABLE LAW, ALL SERVICE OF PROCESS IN ANY PROCEEDING
IN ANY GEORGIA STATE OR UNITED STATES COURT SITTING IN THE CITY OF ATLANTA AND COUNTY OF FULTON MAY BE MADE BY CERTIFIED OR REGISTERED
MAIL, RETURN RECEIPT REQUESTED, DIRECTED TO BORROWER AT THE ADDRESS INDICATED BELOW, AND SERVICE SO MADE SHALL BE COMPLETE UPON
RECEIPT; EXCEPT THAT IF BORROWER SHALL REFUSE TO ACCEPT DELIVERY, SERVICE SHALL BE DEEMED COMPLETE FIVE (5) DAYS AFTER
THE SAME SHALL HAVE BEEN SO MAILED.

 

21.13     Set-Offs.

 

After
the occurrence and during the continuance of an Event of Default, Borrower hereby irrevocably authorizes and directs Lender from
time to time to charge Borrower’s accounts and deposits with Lender (or its Affiliates), and to pay over to Lender an amount
equal to any amounts from time to time due and payable to Lender hereunder, under the Note or under any other Loan Document. Borrower
hereby grants to Lender a security interest in and to all such accounts and deposits maintained by the Borrower with Lender (or
its Affiliates).

 

21.14     Dispute
Resolution.

 

(a)          Arbitration.
Except to the extent expressly provided below, any Dispute shall, upon the request of either party, be determined by binding arbitration
in accordance with the Federal Arbitration Act, Title 9, United States Code (or if not applicable, the applicable state Law),
the then-current rules for arbitration of financial services disputes of AAA and the “Special Rules” set forth below.
In the event of any inconsistency, the Special Rules shall control. The filing of a court action is not intended to constitute
a waiver of the right of Borrower or Lender, including the suing party, thereafter to require submittal of the Dispute to arbitration.
Any party to this Agreement may bring an action, including a summary or expedited proceeding, to compel arbitration of any Dispute
in any court having jurisdiction over such action. For the purposes of this Dispute Resolution Section only, the terms “party”
and “parties” shall include any parent corporation, subsidiary or Affiliate of Lender involved in the servicing,
management or administration of any obligation described in or evidenced by this Agreement, together with the officers, employees,
successors and assigns of each of the foregoing.

 

    	- 49 -

    	 

    

 

(b)          Special
Rules.

 

(i)          The
arbitration shall be conducted in any U.S. state where real or tangible personal property collateral is located, or if there is
no such collateral, in the city and county where Lender is located pursuant to its address for notice purposes in this Agreement.

 

(ii)         The
arbitration shall be administered by AAA, who will appoint an arbitrator. If AAA is unwilling or unable to administer or legally
precluded from administering the arbitration, or if AAA is unwilling or unable to enforce or legally precluded from enforcing
any and all provisions of this Dispute Resolution Section, then any party to this Agreement may substitute another arbitration
organization that has similar procedures to AAA and that will observe and enforce any and all provisions of this Dispute Resolution
Section. All Disputes shall be determined by one arbitrator; however, if the amount in controversy in a Dispute exceeds Five Million
Dollars ($5,000,000), upon the request of any party, the Dispute shall be decided by three arbitrators (for purposes of this Agreement,
referred to collectively as the “arbitrator”).

 

(iii)        All
arbitration hearings will be commenced within ninety (90) days of the demand for arbitration and completed within ninety (90)
days from the date of commencement; provided, however, that upon a showing of good cause, the arbitrator shall be permitted to
extend the commencement of such hearing for up to an additional sixty (60) days.

 

(iv)        The
judgment and the award, if any, of the arbitrator shall be issued within thirty (30) days of the close of the hearing. The arbitrator
shall provide a concise written statement setting forth the reasons for the judgment and for the award, if any. The arbitration
award, if any, may be submitted to any court having jurisdiction to be confirmed and enforced, and such confirmation and enforcement
shall not be subject to arbitration.

 

(v)         The
arbitrator will give effect to statutes of limitations and any waivers thereof in determining the disposition of any Dispute and
may dismiss one or more claims in the arbitration on the basis that such claim or claims is or are barred. For purposes of the
application of the statute of limitations, the service on AAA under applicable AAA rules of a notice of Dispute is the equivalent
of the filing of a lawsuit.

 

(vi)        Any
dispute concerning this arbitration provision, including any such dispute as to the validity or enforceability of this provision,
or whether a Dispute is arbitrable, shall be determined by the arbitrator; provided, however, that the arbitrator shall not be
permitted to vary the express provisions of these Special Rules or the Reservations of Rights in subsection (c) below.

 

(vii)       The
arbitrator shall have the power to award legal fees and costs pursuant to the terms of this Agreement.

 

(viii)      The
arbitration will take place on an individual basis without reference to, resort to, or consideration of any form of class or class
action.

 

(c)          Reservations
of Rights. Nothing in this Agreement shall be deemed to (i) limit the applicability of any otherwise applicable statutes
of limitation and any waivers contained in this Agreement, or (ii) apply to or limit the right of Lender (A) to exercise
self help remedies such as (but not limited to) setoff, or (B) to foreclose judicially or nonjudicially against any real
or personal property collateral, or to exercise judicial or nonjudicial power of sale rights, (C) to obtain from a court
provisional or ancillary remedies such as (but not limited to) injunctive relief, writ of possession, prejudgment attachment,
or the appointment of a receiver, or (D) to pursue rights against a party to this Agreement in a third-party proceeding in any
action brought against Lender in a state, federal or international court, tribunal or hearing body (including actions in specialty
courts, such as bankruptcy and patent courts). Lender may exercise the rights set forth in clauses (A) through (D), inclusive,
before, during or after the pendency of any arbitration proceeding brought pursuant to this Agreement. Neither the exercise of
self help remedies nor the institution or maintenance of an action for foreclosure or provisional or ancillary remedies shall
constitute a waiver of the right of any party, including the claimant in any such action, to arbitrate the merits of the Dispute
occasioning resort to such remedies. No provision in the Loan Documents regarding submission to jurisdiction and/or venue in any
court is intended or shall be construed to be in derogation of the provisions in any Loan Document for arbitration of any Dispute.

 

    	- 50 -

    	 

    

 

(d)          Conflicting
Provisions for Dispute Resolution. If there is any conflict between the terms, conditions and provisions of this Section and
those of any other provision or agreement for arbitration or dispute resolution, the terms, conditions and provisions of this
Section shall prevail as to any Dispute arising out of or relating to (i) this Agreement, (ii) any other Loan Document,
(iii) any related agreements or instruments, or (iv) the transaction contemplated herein or therein (including any claim
based on or arising from an alleged personal injury or business tort). In any other situation, if the resolution of a given Dispute
is specifically governed by another provision or agreement for arbitration or dispute resolution, the other provision or agreement
shall prevail with respect to said Dispute.

 

ARTICLE
22

NOTICES

 

Any
notice, demand, request or other communication which any party hereto may be required or may desire to give hereunder shall be
in writing and shall be deemed to have been properly given (a) if hand delivered, when delivered; (b) if mailed by United States
Certified Mail (postage prepaid, return receipt requested), three Business Days after mailing (c) if by Federal Express or other
reliable overnight courier service, on the next Business Day after delivered to such courier service or (d) if by telecopier on
the day of transmission so long as copy is sent on the same day by overnight courier as set forth below:

 

	If to Borrower:	UCFP Owner, LLC, as Trustee under 
	 	the BR/CDP Colonial Trust Agreement 
	 	dated December 15, 2013
	 	880 Glenwood Avenue SE, Suite H
	 	Atlanta, GA 30316
	 	Attn:  Rob Meyer
	 	Phone: (678) 949-9678
	 	Fax: (404) 890-5681
	 	 
	With a copy to:	BLUEROCK REAL ESTATE, LLC
	 	712 Fifth Avenue, 9th Floor
	 	New York, NY  10019
	 	Attn: Jordan Ruddy and Michael L. Konig
	 	Phone: (908) 415-8869 
	 	Fax: (646) 278-4220
	 	 
	With a copy to:	NELSON MULLINS RILEY & SCARBOROUGH LLP
	 	Atlantic Station
	 	201 17th Street NW, Suite 1700
	 	Atlanta, GA 30363
	 	Attn:  Eric R. Wilensky, Esq.
	 	Phone: (404) 322-6469
	 	Fax: (404) 322-6050

 

    	- 51 -

    	 

    

 

	 	 
	With a copy to:	Hirschler Fleischer
	 	2100 East Cary Street
	 	Richmond, VA  23223
	 	Attn: S. Edward Flanagan, Esq.
	 	Phone:  (804) 771-9592
	 	Fax: (804) 644-0957
	 	 
	If to Lender:	KEYBANK NATIONAL ASSOCIATION
	 	66 South Pearl St., 5th Floor
	 	MSC: NY-31-66-0567
	 	Albany, NY  12207
	 	Attn: Terry Hill
	 	Direct:  (518) 257-8569
	 	Phone:  (518) 257-8572
	 	 
	With a copy to:	KEYBANK NATIONAL ASSOCIATION
	 	1200 Abernathy Road, NE, Suite 1550
	 	Atlanta, GA 30328
	 	Attn: Joe Fadus
	 	Direct:  (770 510-2162
	 	Phone:  (770) 510-2195
	 	 
	With a copy to:	Troutman Sanders LLP
	 	600 Peachtree Street, Suite 5200
	 	Atlanta, GA  30308
	 	Attn:  Jeff Greenway
	 	Phone:  (404) 885-3257
	 	Fax:  (404) 962-6776

 

or at such other address as the
party to be served with notice may have furnished in writing to the party seeking or desiring to serve notice as a place for the
service of notice.

 

ARTICLE
23

 

WAIVER
OF JURY TRIAL

 

BORROWER
AND LENDER EACH WAIVE ANY RIGHT TO A TRIAL BY JURY IN ANY ACTION OR PROCEEDING TO ENFORCE OR DEFEND ANY RIGHTS UNDER THIS AGREEMENT
AND THE OTHER LOAN DOCUMENTS OR RELATING THERETO OR ARISING FROM THE LENDING RELATIONSHIP WHICH IS THE SUBJECT OF THIS AGREEMENT
AND AGREE THAT ANY SUCH ACTION OR PROCEEDING SHALL BE TRIED BEFORE A COURT AND NOT BEFORE A JURY.EXECUTED AS OF THE DATE FIRST
SET FORTH ABOVE.

 

    	- 52 -

    	 

    

 

	BORROWER:	UCFP OWNER, LLC, a Delaware limited liability
    company,
	 	as Trustee under the BR/CDP Colonial Trust Agreement  dated December 15,
    2013
	 	 
	 	By:	/s/ Robert Meyer	 
	 	Name:	Robert Meyer	 
	 	Title:	Vice President 	 

	 	Borrower’s Tax ID No.	90-1035317	 

 

	LENDER:	KEYBANK NATIONAL ASSOCIATION
	 	 	 
	 	By:	/s/ Joseph A. Fadus	 
	 	Name:	Joseph A. Fadus	 
	 	Title:	Senior Vice President 	 

 

    	- 53 -

    	 

    

 

EXHIBIT
A

 

Legal Description
of Land

 

 

 

    	 

    	 

    

 

 

 

 

    	 

    	 

    

 

EXHIBIT
B

 

Permitted
Exceptions

 

 

 

 

    	 

    	 

    

 

 

 

 

 

 

    	 

    	 

    

 

EXHIBIT
C

 

Title Requirements

 

		1.	Title
                                         Insurance Company Requirements. The maximum single risk (i.e., the amount insured
                                         under any one policy) by a title insurer may not exceed 25% of that insurer's surplus
                                         and statutory reserves. Reinsurance must be obtained by closing for any policy exceeding
                                         such amount.

 

		2.	Loan
                                         Policy Forms. Standard 1992 or 2006 American Land Title Association ("ALTA")
                                         form of loan title insurance policy, or the 1970 (amended October 17, 1970) ALTA loan
                                         form policies must be used.

 

		3.	Insurance
                                         Amount. The amount insured must equal at least the original principal amount
                                         of the Loan.

 

		4.	Named
                                         Insured. The named insured under the Title Policy must be substantially the same
                                         as the following: "KeyBank National Association, and its respective successors and
                                         assigns."

 

		5.	Creditors'
                                         Rights. Any "creditors' rights" exception or other exclusion from coverage
                                         for voidable transactions under bankruptcy, fraudulent conveyance, or other debtor protection
                                         laws or equitable principles must be removed by either an endorsement or a written waiver
                                         and an affirmative creditors’ rights endorsement (ALRA Endorsement 21) must be
                                         added.

 

		6.	Arbitration.
                                         In the event that the form policy which is utilized includes a compulsory arbitration
                                         provision, the insurer must agree that such compulsory arbitration provisions do not
                                         apply to any claims by or on behalf of the insured. Please note that the 1987 and 1992
                                         ALTA form loan policies include such provisions.

 

		7.	Date
                                         of Policy. The effective date of the Title Policy must be as of the date and time
                                         of the closing.

 

		8.	Legal
                                         Description. The legal description of the property contained in the Title Policy
                                         must conform to (a) the legal description shown on the survey of the property, and
                                         (b) the legal description contained in the Mortgage. In any event, the Title Policy
                                         must be endorsed to provide that the insured legal description is the same as that shown
                                         on the survey.

 

		9.	Easements.
                                         Each Title Policy shall insure, as separate parcels: (a) all appurtenant easements and
                                         other estates benefiting the property, and (b) all other rights, title, and interests
                                         of the borrower in real property under reciprocal easement agreements, access agreements,
                                         operating agreements, and agreements containing covenants, conditions, and restrictions
                                         relating to the Project.

 

		10.	Exceptions
                                         to Coverage. With respect to the exceptions, the following applies:

 

		a)	Each
                                         Title Policy shall afford the broadest coverage available in the state in which the subject
                                         property is located.

 

		b)	The
                                         "standard" exceptions (such as for parties in possession or other matters not
                                         shown on public records) must be deleted.

 

    	 

    	 

    

 

		c)	The
                                         "standard" exception regarding tenants in possession under residential leases,
                                         should also be deleted. For commercial properties, a rent roll should be attached in
                                         lieu of the general exception.

 

		d)	The
                                         standard survey exception to the Title Policy must be deleted. Instead, a survey reading
                                         reflecting the current survey should be incorporated.

 

		e)	Any
                                         exception for taxes, assessments, or other lienable items must expressly insure that
                                         such taxes, assessments, or other items are not yet due and payable.

 

		f)	Any
                                         lien, encumbrance, condition, restriction, or easement of record must be listed in the
                                         Title Policy, and the Title Policy must affirmatively insure that the improvements do
                                         not encroach upon the insured easements or insure against all loss or damage due to such
                                         encroachment

 

		g)	The
                                         Title Policy may not contain any exception for any filed or unfiled mechanics' or materialmen's
                                         liens.

 

		h)	In
                                         the event that a comprehensive endorsement has been issued and any Schedule B exceptions
                                         continue to be excluded from the coverage provided through that endorsement, then a determination
                                         must be made whether such exceptions would be acceptable to Bank. In the event that it
                                         is determined that such exception is acceptable, a written explanation regarding the
                                         acceptability must be submitted as part of the delivery of the loan documents.

 

If Schedule
B indicates the presence of any easements that are not located on the survey, the Title Policy must provide affirmative insurance
against any loss resulting from the exercise by the holder of such easement of its right to use or maintain that easement. ALTA
Form 103.1 or an equivalent endorsement is required for this purpose.

 

		11.	Endorsements.
                                         With respect to endorsements, the following applies:

 

		a)	Each
                                         Title Policy must include an acceptable environmental protection lien endorsement on
                                         ALTA Form 8.1. Please note that Form 8.1 may take exception for an entire statute which
                                         contains one or more specific sections under which environmental protection liens could
                                         take priority over the Mortgage; provided, however, that such specific sections
                                         under which the lien could arise must also be referenced.

 

		b)	Each
                                         Title Policy must contain an endorsement which provides that the insured legal description
                                         is the same as shown on the survey.

 

		c)	Each
                                         Title Policy must contain a comprehensive endorsement (ALTA Form 9) if a lien, encumbrance,
                                         condition, restriction, or easement is listed in Schedule B to the title insurance policy.

 

		d)	Lender
                                         may require the following endorsements where applicable and available:

 

	 	-access	-due execution	-single tax lot
	 	-address	-first loss	-subdivision
	 	-assessments	-last dollar	-tie in
	 	-assignment of leases and rents	-leasehold	-usury

 

    	- ii -

    	 

    

 

	 	-assignment of loan documents	-mineral rights	-zoning (ALTA 3.1 -
	 	-contiguity	-mortgage tax	with parking)
	 	-doing business	-reverter	 

 

		12.	Other
                                         Coverages. Each Title Policy shall insure the following by endorsement or affirmative
                                         insurance to the extent such coverage is not afforded by the ALTA Form 9 or its equivalent
                                         in a particular jurisdiction:

 

		a)	that
                                         no conditions, covenants, or restrictions of record affecting the property:

 

		(i)	have
                                         been violated,

		(ii)	create
                                         lien rights which prime the insured mortgage,

		(iii)	contain
                                         a right of reverter or forfeiture, a right of reentry, or power of termination, or

		(iv)	if
                                         violated in the future would result in the lien created by the insured mortgage or title
                                         to the property being lost, forfeited, or subordinated; and

 

		b)	that
                                         except for temporary interference resulting solely from maintenance, repair, replacement,
                                         or alteration of lines, facilities, or equipment located in easements and rights of way
                                         taken as certain exceptions to each Title Policy, such exceptions do not and shall not
                                         prevent the use and operation of the Property or the improvements as used and operated
                                         on the effective date of the Title Policy.

 

		13.	Informational
                                         Matters. The Policy must include, as an informational note, the following:

 

		a)	The
                                         recorded plat number together with recording information; and

 

		b)	The
                                         property parcel number or the tax identification number, as applicable.

 

		14.	Delivery
                                         of Copies. Legible copies of all easements, encumbrances, or other restrictions shown
                                         as exceptions on the Title Policy must be delivered with the first draft of the title
                                         commitment.

 

    	- iii -

    	 

    

 

EXHIBIT
D

 

Form of Survey
Certification

 

CERTIFICATION
FOR SURVEYS (LONG-FORM)

 

I hereby
certify to KeyBank National Association, its successors and assigns, and UCFP Owner, LLC, as Trustee under the BR/CDP Colonial
Trust Agreement dated December 15, 2013 and First American Title Insurance Company, that the survey prepared by me entitled "
________ " was actually made upon the ground and that it and the information, courses and distances shown thereon are correct;
that the title lines and lines of actual possession are the same; that the size, location and type of buildings and improvements
are as shown and all are within the boundary lines of the property; that there are no violations of zoning ordinances, restrictions
or other rules and regulations with reference to the location of said building and improvements; that there are no easements,
encroachments or use affecting this property appearing from a careful physical inspection of the same, other than those shown
and depicted thereon; that all utility services required for the operations of the premises either enter the premises through
adjoining public streets, or the survey shows the point of entry and location of any utilities which pass through or are located
on adjoining private land; that the survey shows the location and direction of all storm drainage systems for the collection and
disposal of all roof and surface drainage; that any discharge into streams, rivers or other conveyance system is shown on the
survey; and that the parcels described heron do not lie within flood hazard areas in accordance with the document entitled "Department
of Housing and Urban Development, Federal Insurance Administration - Special Flood Hazard Area Maps". This survey is made
in accordance with the "Minimum Standard Detail Requirements for Land Title Surveys" jointly established and adopted
by ALTA and ACSM in 2011 for Class A Urban Survey and includes items 1-4 and 6-16 of Table A. Pursuant to the Accuracy Standards
as adopted by ALTA, NSPS, and ACSM and in effect on the date of this certification, the undersigned further certifies that: [Surveyor
to complete with appropriate choice from Minimum Standard Detail Requirement]

 

[ALTERNATIVE]

CERTIFICATION
FOR SURVEYS (SHORT FORM)

 

I hereby
certify to KeyBank National Association, and its successors and assigns, and UCFP Owner, LLC, a Delaware limited liability company,
as Trustee under the BR/CDP Colonial Trust Agreement dated December 15, 2013, and First American Title Insurance Company that
the survey prepared by me entitled “______” was actually made upon the ground and that is made in accordance with
the “Minimum Standard Detail Requirements for Land Title Surveys” jointly established and adopted by ALTA and ASCM
in 2011 for Class A Urban Survey.

 

    	 

    	 

    

 

EXHIBIT
E

 

Insurance
Requirements

 

INSURANCE
REQUIREMENTS FOR COMMERCIAL REAL ESTATE LOANS

GROUND-UP
NEW CONSTRUCTION - $15MM to $30MM rev 5/9/14

 

	Named Insured (Borrower): 	UCFP Owner, LLC
	Collateral Property Address:	12231 E. Colonial Drive
	 	Orlando, FL 32826

 

	Mortgagee: 	KeyBank National Association,
    its successors and/or assignees, for itself and, when applicable, as agent for other participating lenders
	 	 
	Mortgagee address:	KeyBank Real Estate Capital, Attention: Insurance
    Dept  

    11501 Outlook Street, Suite #300, Overland Park, KS 66211

 

Deductible
under any line of coverage (except flood, quake and named windstorm) must not exceed $25,000. 

 

BUILDER’S RISK –
NOTE: EVIDENCE OF INSURANCE MUST ADDRESS ALL THESE POINTS

	Required coverage and conditions:	 	·	“Special
    Form” equivalent to ISO standard, or “Risks of loss not otherwise excluded” for coverage comparable to ISO
    Special Form, including damage from windstorm and hail
	 	 	·	Boiler
    & Machinery or Breakdown coverage for buildings with boilers, elevators or central HVAC (not required for per-unit HVAC)
	 	 	·	Completed
    value coverage form.  Limit available for loss payment must not be affected by status of interim reports of value
    to insurer.
	 	 	·	Replacement
    cost valuation
	 	 	·	No
    coinsurance / coinsurance waived
	 	 	·	Permission
    to complete and occupy – for projects where occupancy will occur in stages before all work is complete
	Amount of insurance:	 	Building Limit – sufficient to
    cover materials and supplies and all hard costs of vertical construction, including value of foundations and contingency,
    $ 23,581,023
	 	 	 
	  	  	Materials and supplies – sufficient
    to cover maximum values at any time off site, and in transit if borrower takes title before delivery $250,000
	 	 	 
	 	 	Soft costs $906,109 plus
    $2,547,839 for loss of income due to delayed occupancy (a combined limit or separate limits for these elements will be
    acceptable).  At minimum, soft cost limit must include full budget for loan interest, insurance premiums, and real
    estate tax.  Loss of income should cover 12 months’ projected income.
	Additional causes of loss if specified:	 	 ̈
        Flood – mandatory at NFIP limits
        ($250,000 per residential bldg., $500,000 per commercial bldg.) if property is in Special Flood Hazard Area

         ̈
        Additional or alternative flood limits:
        $1,000,000

	 	 	 ̈
    Earthquake $1,000,000 min.; up to 25% of
    value if location is high-risk for earthquake
	 	 	 ̈
    Terrorism

 

    	 

    	 

    

 

	 	 	x
    Ordinance or Law:  
	 	 	(A) Loss
    of value of undamaged part – within full building limit (if sublimit applies, it should be at least 25% of hard
    cost value); 
	 	 	(B) Demolition
    and (C) Increased Cost of Construction: $1,000,000
	 	 	 ̈
    Other
	 	 	 
	Mortgagee Clause:	 	Mortgagee identified as
        above.

        Mortgagee provisions
        must match standard clause of ISO forms or Lender’s Loss Payable clause per section D of ISO form CP 12 18 (06-07);
        INCLUDE COPY WITH CERTIFICATE

	 	 	 
	Documentation:	 	Acord 28 Evidence of Property Insurance
    
	 	 	·	All
    details specified above must be specifically addressed.  
	 	 	·	All
    deductibles and any sub-limits must be disclosed.
	 	 	·	If
    program is blanket over other locations as well as loan property, show policy limits along with values reported to insurer
    for the subject location.

 

(NOTE:
When building is complete and certificate of occupancy is issued, building should be transitioned to “all risk” or
“special form” Property insurance, documented to lender with form, terms, and conditions acceptable to lender.)

 

GENERAL LIABILITY

 

	Coverage form:	 	Commercial General Liability
    (not Owners & Contractors Protective) – equivalent to ISO standard occurrence-based form, including Bodily Injury,
    Property Damage, Personal & Advertising Injury, Contractual Liability, and completed operations – unless otherwise
    agreed by Lender
	Limit of liability per
        occurrence:

         
	 	 

        During Construction
        not less than $1,000,000 per occurrence / $2,000,000 aggregate primary liability coverage.

        At the time that the first
        unit is ready for occupancy, $1,000,000 per occurrence /$ 2,000,000 aggregate primary liability coverage and $9,000,000
        in excess liability shall be required.

         

	Mortgagee as Additional
        Insured:

         
	 	Mortgagee identified on
        page 1.

        Coverage granted per ISO
        form CG 20 18 or CG 20 26, or equivalent.

        INCLUDE
        COPY OF ENDORSEMENT OR POLICY PROVISIONS WITH CERTIFICATE. 

         

	Documentation:	 	Acord 25 Certificate of
        Liability Insurance

         

 

BORROWER’S PROPERTY,
GENERAL LIABILITY AND UMBRELLA/EXCESS INSURERS MUST HAVE BEST’S RATINGS NOT LESS THAN A:X UNLESS OTHERWISE AGREED
TO BY LENDER.

 

OTHER COVERAGES

 

	Workers’ Compensation:	 	Statutory benefits for the state
    where the building is located.  This requirement may be waived if borrowing entity has no employees and general
    contractor produces evidence of workers’ compensation coverage.

 

    	- ii -

    	 

    

 

	Employer’s Liability:	 	$100,000 per accident
        for accidental injury; $100,000 per employee and $100,000 aggregate for occupational illness or disease.

         

	Business Auto Liability:	 	Covering owned, non-owned and hired/rented vehicles

 

    	- iii -

    	 

    

 

EXPECTATIONS FOR GENERAL CONTRACTOR’S
INSURANCE:

 

	General Liability:	 	Commercial General Liability –
    equivalent to ISO standard occurrence-based form, including Bodily Injury, Property Damage, Personal & Advertising Injury,
    Contractual Liability, and covering completed operations.  
	 	 	·	Covering
    Borrower (and lender, if possible) as Additional Insured for current work.
	 	 	·	When
    obtainable, covering Borrower (and lender, if possible) as Additional Insured for completed work if occupancy will occur in
    stages before all work is complete
	 	 	INCLUDE
    COPIES OF ENDORSEMENTS WITH CERTIFICATE.  
	 	 	Certificate
    must say “does not exclude residential work” if project is residential.
	 	 	 
	Limit of liability per
        occurrence:

         
	 	 

        Not less than $10,000,000
        combining primary and excess

         

	Workers’ Compensation:	 	Statutory benefits for state where
    work will be performed.

 

    	- iv -

    	 

    

 

EXHIBIT
F

 

Architect’s
Certificate

 

The
firm of _________________________________________ hereby certifies for the benefit of KeyBank National Association that:

 

The
firm has been employed by ___________________________ pursuant to a contract dated __________________________ to
provide architectural and engineering services commonly known as __________________________ which is located at ____________________________________________________.

 

The
contract provides for the following services:

 

	 	 	preparation of plans and specifications
	 	 	Pre-qualification of contractors
	 	 	Contract administration and supervision of construction
	 	 	Tenant space design
	 	 	 
	 	 	 

 

The
firm is duly licensed and in good standing under laws of the state of ______________ License No. _____________________________.

 

The
foundations were designed in accordance with the recommendations contained in a soil report dated _____________________________
which was prepared by __________________________________________________________.

 

The
following are all of the permits or governmental agency approvals required for the construction and occupancy of the building:

 

	 	Issuing
    Agency	 	Date
        Issued

	 	 	 	 
	Excavation Permit	 	 	 
	Foundation Permit	 	 	 
	Building Permit	 	 	 
	EPA – Water	 	 	 
	EPA – Sewer	 	 	 
	EPA – Air	 	 	 
	 	 	 	 
	Cert. Of Occupancy Bldg.	 	 	 
	Cert. Of Occupancy – Tenant	 	 	 
	Other (Specify)	 	 	 
	 	 	 	 
	 	 	 	 

 

    	 

    	 

    

 

All
utilities necessary for the operation of the project are available with sufficient capacity at the boundaries of the project.
If utility services must be brought to site, please explain: ___________________________________________

	 
	 	.

 

The
plans listed on the attached Schedule I comprise all of the plans which will be necessary for the complete construction of the
project, excepting tenant space designs, and when the project is built in accordance therewith the project will (excepting completion
of tenant improvements) be ready for occupancy. The plans are complete and contain all detail necessary for construction. Calculations
of the gross building and the net rentable building area are attached as Schedule II. The plans (and the project will, when constructed
in accordance therewith) comply with all applicable building, zoning, land use, subdivision, environmental, fire, safety and other
applicable governmental laws, statutes, codes, ordinances, rules and regulations.

 

The
attached Schedule III, establishing a timetable for completion of the project and showing on a monthly basis the anticipated progress
of the work, is realistic and can be adhered to.

 

The
following design drawings or plans have been or will be prepared by other designers or contractors.

 

	Type
    of Plans	 	Name
    of Preparing Firm
	 	 	 
	 	 	 
	 	 	 
	 	 	 

 

	The Specifications are:	_________________________
    shown on plans
	 	_________________________
    Bound separately

 

	 	By:	 
	 	Title:	 
	 	Date:	 

 

    	- ii -

    	 

    

 

EXHIBIT
G

 

Initial Budget

 

 

 

    	 

    	 

    

 

EXHIBIT
H

 

Borrower’s
Certificate

 

KeyBank National Association

127 Public Square, 6th
Floor

Cleveland, OH 44114

 

ATTN: COMMERCIAL REAL ESTATE DEPARTMENT

 

		RE:	Application
                                         for Disbursement or confirmation of equity contribution in connection with a $27,500,000.00
                                         loan (#______________________) to UCFP Owner, LLC, a Delaware limited liability company,
                                         as Trustee under the BR/CDP Colonial Trust Agreement dated December 15, 2013 (“Borrower”).

 

		1.	Pursuant
                                         to that certain Construction Loan Agreement dated _______________, 2014 (the “Construction
                                         Loan Agreement”) between Borrower and KeyBank National Association (“Lender”),
                                         Borrower

 

		(a)	hereby
                                         requests a Loan disbursement as indicated on the Soft and Hard Cost Requisition attached
                                         hereto. We acknowledge that this amount is subject to inspection, verification, and available
                                         funds.

 

		(b)	acknowledges
                                         and confirms an equity contribution as indicated on the Soft and Hard Cost Requisition
                                         attached hereto.

 

Funding
Instructions

 

		2.	This
                                         Borrower’s Certificate is to be utilized only in satisfaction of costs and charges
                                         with respect to the Project and Improvements thereon as shown on the Soft and Hard Cost
                                         Requisition Form, dated ____________________, attached hereto.

 

		3.	The
                                         Borrower agrees to provide, if requested by Lender, a Vendor Payee Listing showing the
                                         name and the amount currently due each party to whom Borrower is obligated for labor,
                                         material and/or services supplies. This information would be provided in support of the
                                         disbursements set forth in paragraph 1(a) hereof.

 

		4.	The
                                         Borrower also certifies and agrees that:

 

		(a)	It
                                         has complied with all duties and obligations required to date to be carried out and performed
                                         by it pursuant to the terms of the Construction Loan Agreement;

 

		(b)	No
                                         Event of Default as defined in the Construction Loan Agreement, nor any event, circumstance
                                         or condition which with notice or the passage of time or both would be an Event of Default,
                                         has occurred and is continuing and;

 

		(c)	All
                                         Change Orders or changes to the Schedule of Values have been submitted to and approved
                                         by Lender to the extent required under the Construction Loan Agreement;

 

    	 

    	 

    

 

		(d)	All
                                         funds previously disbursed have been used for the purposes as set forth in the Construction
                                         Loan Agreement;

 

		(e)	All
                                         outstanding claims for labor, materials and/or services furnished prior to this draw
                                         period have been paid or will be paid from the proceeds of this disbursement;

 

		(f)	All
                                         construction prior to the date of this Borrower’s Certificate has been accomplished
                                         in accordance with the Plans and Specifications approved by Lender;

 

		(g)	All
                                         sums advanced by Lender will be used solely for the purpose of paying costs of the Project
                                         owing as shown on the attached Soft and Hard Cost Requisition and no disbursement requested
                                         hereunder has been the basis for any prior disbursement of the Loan;

 

		(h)	There
                                         are no liens outstanding against the subject project or its equipment except for Lender’s
                                         liens and security interests as agreed upon in the Construction Loan Agreement;

 

		(i)	The
                                         amount of undisbursed Loan proceeds and/or approved equity requirement remaining is sufficient
                                         to pay the cost of completing the Project in accordance with the Plans and Specifications
                                         and Budget approved by Lender as modified by Lender in approved Changed Orders;

 

		(j)	All
                                         representations and warranties contained in the Construction Loan Agreement are true
                                         and correct as of the date hereof.

 

		(k)	The
                                         undersigned understands that this certification is made for the purpose of inducing Lender
                                         to make a disbursement to Borrower and that, in making such disbursement, Lender will
                                         rely upon the accuracy of the matters stated in this Certificate.

 

		5.	Disbursement
                                         of the loan proceeds hereby requested are subject to the receipt by Lender, in those
                                         states where applicable, of a certificate from the issuing title company stating that
                                         no claims have been filed of record which adversely affects the title of Borrower to
                                         the Project, subsequent to the filing of the Lender’s Mortgage.

 

		6.	The
                                         terms used in this Borrower’s Certificate have the same meaning and definitions
                                         as those set forth in the Loan Agreement.

 

		7.	The
                                         Borrower, or authorized signer, certifies that the statements made in this Borrower’s
                                         Certificate and any documents submitted herewith and identified herein are true and has
                                         duly caused this Borrower’s Certificate to be signed on its behalf by the undersigned
                                         Authorized Representative.

 

[SIGNATURE
PAGE ON FOLLOWING PAGE]

 

    	- 2 -

    	 

    

 

	 	DATE:	 
	 	 
	 	BORROWER:
	 	 
	 	UCFP OWNER, LLC, a Delaware limited liability
    company, as Trustee under the BR/CDP Colonial Trust Agreement dated December 15, 2013
	 	 	 
	 	By:	 
	 	Name:	 
	 	Title:	 

 

    	- 3 -

    	 

    

 

EXHIBIT
I

 

Soft and Hard
Cost Requisition Form

 

 

  

    	 

    	 

    

 

 

   

    	 

    	 

    

 

EXHIBIT
J

 

Certificate
of Compliance

 

KeyBank National Association

________________________

________________________

 

Re: Construction
Loan Agreement dated as of ________ (as amended, modified, supplemented, restated, or renewed, from time to time, the “Agreement”),
between UCFP OWNER, LLC, a Delaware limited liability company, as Trustee under the BR/CDP Colonial Trust Agreement dated
December 15, 2013 (the “Borrower”), and KEYBANK NATIONAL ASSOCIATION (“Lender”).

 

Reference
is made to the Agreement. Capitalized terms used in this Certificate (including schedules and other attachments hereto, this “Certificate”)
without definition have the meanings specified in the Agreement.

 

Pursuant
to applicable provisions of the Agreement, the undersigned, being the Authorized Representative designated in the Agreement, hereby
certifies to the Lender that the information furnished in the attached schedules, including, without limitation, each of the calculations
listed below are true, correct and complete in all material respects as of the last day of the fiscal periods subject to the financial
statements and associated covenants being delivered to the Lender pursuant to the Agreement together with this Certificate (such
statements the “Financial Statements” and the periods covered thereby the “reporting period”) and for
such reporting periods.

The undersigned hereby further
certifies to the Lender that:

 

1.          Compliance
with Financial Covenants. As shown below, the Guarantor Alsar Limited Partnership (“Alsar”) is in full compliance
with the Unencumbered Liquid Assets covenant contained in Section 23 of the Payment Guaranty dated May 14, 2014, executed by Alsar
in favor of Lender (the “Alsar Payment Guaranty”).

 

A.           Covenant:
Alsar’s Unencumbered Liquid Assets to be not less than the Principal Obligation Amount (as defined in the Alsar Payment
Guaranty) in the amount of [$__________].

 

Calculation: Liquidity
= Cash and Cash Equivalents + Marketable Securities.

 

Guarantors’ Liquidity______________
for period ending __________________

 

[See attached financial
statement]

 

Compliance?
(Yes or No)

 

2.          Review
of Condition. The undersigned has reviewed the terms of the Agreement, including, but not limited to, the representations
and warranties of the Borrower and Guarantors set forth in the Agreement and the covenants of the Borrower set forth in the Agreement,
and has made, or caused to be made under his or her supervision, a review in reasonable detail of the transactions and condition
of the Borrower and Guarantors through the reporting periods.

 

    	-ii

    	 

    

 

3.          Representations
and Warranties. To the undersigned’s actual knowledge, the representations and warranties of the Borrower and Guarantors
contained in the Loan Documents, including those contained in the Agreement, are true and accurate in all material respects as
of the date hereof and were true and accurate in all material respects at all times during the reporting period except as expressly
noted on Schedule A hereto.

 

4.          Covenants.
To the undersigned’s actual knowledge, during the reporting period, the Borrower observed and performed all of the respective
covenants and other agreements under the Agreement and the Loan Documents, and satisfied each of the conditions contained therein
to be observed, performed or satisfied by the Borrower, except as expressly noted on Schedule A hereto.

 

5.          No
Event of Default. To the undersigned’s actual knowledge, no Event of Default exists as of the date hereof or existed
at any time during the reporting period, except as expressly noted on Schedule A hereto.

 

IN WITNESS WHEREOF, this Certificate
is executed by the undersigned this ____ day of __________.

 

	 	UCFP OWNER, LLC, a Delaware limited liability company,
	 	as Trustee under the BR/CDP Colonial Trust Agreement  dated December 15,
    2013
	 	 
	 	By:	 
	 	Name:	 
	 	Title:	 

 

    	-iii

    	 

    

 

EXHIBIT
K

 

LIBOR NOTICE
ELECTION

 

NOTICE OF
LIBOR FUNDING ELECTION

 

	KeyBank National Association
	 

 

Date: ___________________

 

Ladies and Gentlemen:

 

Reference
is made to the Promissory Note dated as of May 14, 2014, made by UCFP OWNER, LLC, a Delaware limited liability company, as Trustee
under the BR/CDP Colonial Trust Agreement dated December 15, 2013, in favor of KeyBank National Association (the “Note”).
The undersigned hereby gives notice pursuant to Section 5.1 of the Loan Agreement referenced in the Note of its desire for a LIBOR
FUNDING ELECTION of a portion of the proceeds of the loan evidenced by the Note.

 

The
following are the details of the LIBOR funding election to be set up as of the commencement date specified below:

 

	 	1.	The LIBOR funding commencement date
    is:	 
	 	 	 	 
	 	2.	The LIBOR funding period expires:	 
	 	 	 	 
	 	3.	The LIBOR funding principal amount is:	 
	 	 	 	 
	 	4.	The LIBOR funding rate is LIBOR plus ___%, or	 

 

The
sources for the above LIBOR are as follows (Choose as appropriate):

 

Prime
Note Outstanding Balance:

Draw
#____ Advance:

Interest
due:

Current
LIBOR maturing _____:

Current
LIBOR maturing _____:

Total:

 

The
next LIBOR FUNDING ELECTION NOTIFICATION date is ______.

 

    	-iv

    	 

    

 

EXHIBIT
L

 

FORM OF
CONSTRUCTION LOAN UPDATE ENDORSEMENT

 

[Attached]

 

 

 

    	-v

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00234-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00234-of-00352.parquet"}]]