Document:

exv10w14

EXHIBIT 10.14

[LETTERHEAD OF IMPAX LABORATORIES, INC.]

November 12, 2008

Mr. Christopher Mengler

OFFER
OF EMPLOYMENT

Dear Chris,

This letter constitutes an offer of employment for you to join Impax Laboratories, Inc. (IMPAX) as
the President, Generic Products Division (Global Pharmaceuticals). In this position you will
report to Larry Hsu, PhD., President and CEO. You will be based out of our Chalfont, PA office.

In this position your salary will be $17,115.40 paid biweekly ($445,000.00 annually). You will be
eligible to participate in the Corporate Management Bonus Program. The target bonus eligibility
for this position is 75% of base salary. This bonus may be prorated for 2009 depending on your
start date.

You will also receive, pending Shareholder and Board of Director approval, an option to purchase
75,000 shares of IMPAX stock, plus 30,000 Restricted Stock Units. The shares you will be given the
opportunity to purchase will vest in accordance with the normal vesting schedule of 25% per year,
so long as you remain employed by the Company. However, the grant of such option by the Company is
subject to Shareholder and Board approval to recommend such approval is not a promise of
compensation and is not intended to create any obligation on the part of the Company. Further
details on the Plan and any specific option grant to you will be provided upon approval of such
grant by the Company’s Board of Directors.

In addition, you will receive a one time hiring bonus of $75,000.00 (less applicable taxes) to be
paid as follows: $37,500.00 after thirty (30) days of employment, $37,500.00 on the first payroll
date following your one-year anniversary date with the Company. Should your employment with IMPAX
be terminated voluntarily or for cause, within a one-year period of your hire date, the first
payment of the hiring bonus shall be recovered in full. Should your employment with IMPAX be
terminated voluntarily or for cause, within the second year period of your hire date, the second
payment of the hiring bonus shall be recovered in full. Your employment start with IMPAX will be
no later than Monday, January 30, 2009, unless a different date is mutually agreed between you and
the Company. Please confirm your start date with the Company as soon as possible and report for
New Hire Orientation at 8:00 am in our Chalfont location on your first day.

You will be eligible to participate in the medical and dental insurance coverage provided by the
company the first of the month following one month of employment. You will be eligible for these
benefits on March 1, 2009, assuming the start date indicated above. You will be eligible to
participate in the Company’s group term life, and group long-term and short-term disability
coverage the first of the month following three months of employment. You will be eligible to
participate in the 401K Plan on April 1, 2009, assuming the start date indicated above. This is
the first of the quarter following one month of employment. You will also be eligible to
participate in the Executive Non Qualified Deferred Compensation Plan on your hire date. You will
also receive sixteen (16) days of Paid Time Off (PTO) that accrue on a weekly basis. Paid Time Off
(PTO) can not be used until it is earned.

 

 

You will be entitled to participate in or receive benefits under any other employee benefit plan
made available by the company in the future to its employees subject to, and on a basis consistent
with, the terms, conditions and overall administration of such plans.

Please note that this employment offer is contingent upon a successful completion of a drug test,
background check and credit check paid by the Company. We utilize the services of the Frankford
Hospital WorkHealth Clinics for drug testing. You must contact them directly to schedule an
appointment. Please do so within 48 hours of your signed acceptance of this letter. You may use
any one of the Frankford WorkHealth Clinic sites. Information regarding drug testing locations is
enclosed. An Authorization Form (enclosed) and picture ID are required for testing. A positive
result will mandate the rescission of this offer.

To comply with the Department of Justice Immigration and Control Act, you will need to provide
documentation that supports employment eligibility within the United States. Please bring your
documentation with you on your Orientation Day. If you would like a list of acceptable documents,
please contact Human Resources. Please bring a voided check or savings account document if you are
interested in Payroll Direct Deposit.

Please note that your employment is at will. Accordingly, either you or the company can terminate
the employment relationship at any time, with our without advance notice. This offer does not
constitute any promise or obligation of any duration of employment nor severance package. If this
offer is acceptable, please return the signed original document to Human Resources by confidential
fax at 215-933-0330.

Chris, we believe that you will contribute to the company’s overall success and that IMPAX will
provide you the career environment and opportunities that you seek. We look forward to your
joining the IMPAX team. If you have any questions please contact Human Resources at 215-933-0357.

Sincerely,

	 	 	 
	/s/ Paul R. Ulatoski
	 	 
	 

Paul R. Ulatoski

	 	 
	Vice President Human Resources
	 	 
	Impax Laboratories, Inc.
	 	 
	 
	 	 
	CC: Larry Hsu
	 	 

	 	 	 
	Accepted by:
	 	 
	 
	 	 
	/s/ Christopher Mengler

	 	Date: 29 – DEC – 08
	 
	 	 
	Christopher Menglerexv10w26

EXHIBIT 10.26

IMPAX Laboratories (Taiwan), Inc.

IMPAX Jhunan Plant Project

MEP Construction Package

Construction Work Agreement

Owner:

IMPAX Laboratories (Taiwan), Inc

No. 11, Ke June Rd., Jhunan, Miao-Li, Taiwan, ROC

Contractor:

E&C Engineering Corporation

19 F, No. 77, Tun Hwa S. Rd., Sec. 2, Taipei, Taiwan, ROC

March 27, 2008

 

 

IMPAX Laboratories (Taiwan), Inc.

MEP Construction Package for IMPAX Jhunan Plant Project

Construction Work Agreement

CONTENT

	 	 	 	 	 
	1. DEFINITIONS AND INTERPRETATION
	 	 	1	 
	2. SCOPE OF WORK
	 	 	1	 
	3. AGREEMENT SUM AND PAYMENT
	 	 	2	 
	4. TAX AND DUTIES
	 	 	2	 
	5. WORK SCHEDULE
	 	 	2	 
	6. CHANGES AND ADDITIONAL WORK
	 	 	3	 
	7. ADDITIONAL PAYMENT
	 	 	3	 
	8. DELAY AND EXTENSION OF TIME
	 	 	3	 
	9. TERMINATION AND LIMITATION OF LIABILITY
	 	 	4	 
	10. FORCE MAJEURE – DELAY BEYOND CONTROL
	 	 	5	 
	11. INDEMNITY
	 	 	5	 
	12. PROPERTY AND RISK
	 	 	6	 
	13. INSURANCE
	 	 	6	 
	14. INDEPENDENT CONTRACTOR
	 	 	6	 
	15. ASSIGNMENT AND SUBCONTRACTING
	 	 	6	 
	16 PERFORMANCE BOND
	 	 	7	 
	17. ACCEPTANCE OF THE WORK
	 	 	7	 
	18. WARRANTY
	 	 	7	 
	19. DISPUTE RESOLUTION
	 	 	8	 
	20. NOTICES
	 	 	8	 
	21. GOVERNING LAW
	 	 	9	 
	22. AMENDMENT
	 	 	9	 
	23. ENTIRE AGREEMENT
	 	 	9	 

Attachment A SCOPE OF WORK

Attachment B PRICE BREAKDOWN

- i -

 

IMPAX Laboratories (Taiwan), Inc.

MEP Construction Package for IMPAX Jhunan Plant Project

Construction Work Agreement

This Construction Work Agreement (hereinafter, together with the attachment annexed hereto and
forming an integral part hereof, called “the Areement”), is entered into on February 18, 2008, by
and between:

IMPAX Laboratories (Taiwan), Inc., a corporation organised and existing under the laws of Republic
of China with its its principal place of business at No. 11, Ke June Rd., Jhunan, Miao-Li, Taiwan,
ROC (hereinafter referred to as “IMPAX”), and

E&C Engineering Corporation, a corporation organised and existing under the laws of Republic of
China with its its principal place of business at 19 F, No. 77, Tun Hwa S. Rd., Sec. 2, Taipei,
Taiwan, ROC (hereinafter referred to as “the Contractor”);

WHEREAS, IMPAX engages the Contractor for the “MEP Construction Package” (hereinafter referred to
as “the Work” for its “IMPAX Jhunan Plant Project” (hereinafter referred to as “the Project”), to
be carried out at IMPAX’s Jhunan Plant site, and in consideration of these premises and of the
mutual undertakings hereunder, the parties agree as follows:

	1.	 	DEFINITIONS AND INTERPRETATION
	 
	1.1	 	In the Agreement the following words and expressions shall have the meanings hereby assigned
to them except when the context otherwise requires:

	 	a.	 	“Agreement” means this Agreement and its attachments hereto.
	 
	 	b.	 	“Agreement Sum” means the total agreed price for the services rendered by the
Contractor for Work under this Agreement.
	 
	 	c.	 	“Work” means the works described in the documents identified in the Attachment A
hereto with reference to the works.
	 
	 	d.	 	“Work Product” means anything created or developed by Contractor in performing
Work, including all data, documents, reports, drawings, designs, models, ideas and
improvements, electronic data (in usable form), and other intellectual property
including copyrights, patents, trademarks, and trade secrets. Excluded from Work
Product are questionnaire formats, methods for collecting data, patents, tradenames, and
databases owned or licensed by Contractor.
	 
	 	e.	 	“Site” means where the Project is located; address: Land Lot No. 39-1 in the
Jhunan Science Park, Jhunan, Miao-Li, Taiwan, ROC.

	1.2	 	Unless otherwise expressly provided, all payments shall be made hereunder in New Taiwan
Dollar.
	 
	2.	 	SCOPE OF WORK

-1-

 

	 	 	Contractor shall, except to the extent otherwise expressly stated herein, furnish all labor,
supervision, materials, tools, equipment, facilities, permits, and activities to properly and
efficiently do all things necessary to perform the Work, as further defined in Attachment
A, Scope of Work which is attached hereto and included herein. This Scope of Work may be
modified from time to time by mutual written agreement.
	 
	3.	 	AGREEMENT SUM AND PAYMENT
	 
	3.1	 	The Agreement Sum for the execution of the Work is New Taiwan Dollar One Hundred Seventy
Eight Million and Eight Hundred Thousand (NTD178,800,000), excluding ROC Value Added Tax. ROC
Value Added Tax shall be for the account of IMPAX. The detailed price breakdown is annexed
herein as Attachment B.
	 
	3.2	 	Terms of payment are as below:

	 	a.	 	90% of the Agreement Sum payable by monthly progress;
	 
	 	b.	 	10% of the Agreement Sum payable upon final Acceptance by IMPAX, or within six
(6) months after IMPAX obtains Building Occupancy Permit from local authority, whichever
occurs first.

	3.3	 	Contractor shall invoice IMPAX before the 10th day of every month for its Work
properly provided under the Agreement during the preceding month. IMPAX shall review and
approve the invoice within ten (10) days after its receipt. The invoice shall be deemed as
approved by IMPAX if it does not approve nor stating its objection to the invoice within such
period of time. Payment is due within 30 days after invoice approved.
	 
	4.	 	TAX AND DUTIES
	 
	4.1	 	All rates and prices set forth in the Agreement shall be inclusive of all Taxes, Duties,
Charges and the like, except for the ROC Value Added Tax.
	 
	4.2	 	The Contractor shall obtain immunity or exemption from taxes or duties from which the
Contractor or its subcontractors are exempt under applicable law or shall obtain a refund or
credit including interest applicable for any such taxes or duties paid. If the Contractor
negligently fails to obtain said immunities, exemptions refunds, or credits such taxes and
duties shall be to the Contractor’s account.
	 
	4.3	 	The Contractor shall however be deemed to have included in the Contract Sum for all costs and
expenses arising out of or in relation to the administration of all Taxes, Duties and Charges
payable by him on the services purchased for the carrying out and bringing to completion of
the Work. Such cost and expense shall include but not limited to all administrative costs,
financial charges, etc.
	 
	5.	 	WORK SCHEDULE
	 
	 	 	The Contractor agrees to commence Work under this Agreement from the commencement date stated
in the IMPAX Letter of Intent, dated 11 December 2007, and shall complete Phase 1-A of this
Work by May 31, 2008 and complete Phase 1-B of this Work by September 30, 2008 (refer to
Attachement A for the scopes of Phase 1-A and Phase 1-B), unless the deadlines have been
extended in accordance with Article 8 of this Agreement.

-2-

 

	 	 	In no event shall the Work to be performed under this Agreement be considered to be complete
until all construction items called for on the drawings, and specifications have been
completed.
	 
	6.	 	CHANGES AND ADDITIONAL WORK
	 
	6.1	 	With prior written direction, IMPAX may make changes in the Work or authorize additional
works which shall be performed under and be subject to the applicable conditions of this
Agreement. In all cases where the amount or character of the Work is affected, an adjustment
to Contractor’s compensation and/or schedule should be agreed upon by both parties.
	 
	6.2	 	All changes or additional works must be authorized in writing by IMPAX before said work is
begun.
	 
	6.3	 	Notwithstanding anything to the contrary herein contained, Contractor shall not however be
entitled to any additional compensation or an extension of time under Contractor’s schedule if
any change or additional work required by IMPAX as aforesaid is necessitated by any event
caused by the negligence omission or default of the Contractor.
	 
	6.5	 	IMPAX may at its sole direction also issue instruction in regard to the stoppage or
postponement of any part of the Work to be performed under the provisions of the Agreement. If
the schedule for the performance of the work is affected by such stoppage and postponement and
unless such stoppage and postponement is necessitated by any event caused by the negligence
omission or default of Contractor, IMPAX shall allow Contractor such extension of time as is
reasonable and, provided that the stoppage or postponement has been longer than 180 days, the
Contractor shall be entitled to additional costs and/or expenses directly incurred therefrom,
during the period of stoppage or postponement. If Contractor proceed with the Work after being
issued with instructions to stop or postpone, then Contractor shall be responsible for the
removal or correction of such work and for any other damages or losses suffered or incurred by
IMPAX.
	 
	7.	 	ADDITIONAL PAYMENT
	 
	 	 	The Contractor shall not be entitled to claim additional costs that incur during the
performance of the Work as in example for a prolonged period of time (exceeding Agreement
Completion Schedule) or extra works (exceeding Agreement Work) unless such extra costs have
been approved by IMPAX in regard to the Agreement.
	 
	8.	 	DELAY AND EXTENSION OF TIME
	 
	8.1	 	In the event Work performed by Contractor fails to conform with the generally accepted
engineering standards, or Contractor personnel is incompetent for the assigned works, IMPAX or
the supervisors assigned by IMAX may notify Contractor at any time and Contractor shall make
corrections as instructed by IMPAX or the supervisors without requesting additional payment,
and shall maintain the original schedule.
	 
	8.2	 	In the event of delays or inability to fulfill contractual obligations due to Force Majeure,
the affected party shall not be deemed in breach of the Agreement.
	 
	8.3	 	If the Contractor fails to meet any of the deadlines provided in Article 5 of this Agreement
or in delay with his other contractual duties of which the performance

-3-

 

	 	 	shall be due the latest
at the written demand from IMPAX, he shall pay a liquidated damage and not as a penalty for
each day of delay. The daily liquidated damages for not meeting such contractual duty shall be
0.1% of the Agreement Sum up to the limit of 20% hereof.
	 
	8.4	 	If any of the deadlines must be extended as a result of one of the following circumstances,
the Contractor shall notify IMPAX of his request by a written notice together with supporting
documents. IMPAX may at his option extend the deadline after evaluating Contractor
justifications for the delay and therefore waive the liquidated damage:

	 	a.	 	As a consequence of Force Majeure;
	 
	 	b.	 	Any Agreement amendment for which Contractor is not responsible or Contractor
suspension of the project execution as notified by IMPAX;
	 
	 	c.	 	IMPAX has not provided the required information, equipment or sites to Contractor
or taken the required matching measures such as evaluation or approval in accordance
with the Agreement requirements;
	 
	 	d.	 	Any delay for which another supplier establishing a contractual relationship with
IMPAX is responsible;
	 
	 	e.	 	Any other causes for which IMPAX is liable or Contractor is not responsible.

	9.	 	TERMINATION AND LIMITATION OF LIABILITY
	 
	9.1	 	In the event that the Contractor has been behind any of the deadlines provided in Article 5
of this Agreement for thirty (30) days, or in the event that the Contractors reveals inability
to complete this Project on schedule, IMPAX is entitled to, with written notice, terminate
this Agreement.
	 
	9.2	 	In the event IMPAX or Contractor is in breach or default of this Agreement, or any material
provisions thereof, and does not act to remedy such breach or default within thirty (30)
calendar days after written Notice is given, this Agreement may at any time thereafter be
suspended or terminated, in whole or in part, by the other Party. In the case of termination,
the Notice shall specify an effective date that provides for an orderly shutdown of the Work.
	 
	9.3	 	Upon termination, Contractor shall take appropriate steps promptly to terminate the affected
Work in an orderly manner, and to terminate pertinent outstanding obligations and commitments
with a reasonable cost to IMPAX. Contractor shall conduct these termination steps in a proper
manner or take necessary steps in order not to cause IMPAX damages.
	 
	9.4	 	Termination of this Agreement, for whatever reason, shall not prejudice or affect the accrued
rights or claims and liabilities of either party to this Agreement.
	 
	9.5	 	The Contractor’s maximum aggregate liability in connection with all claims under this
Agreement, including liquidated damage for delay as stated above, shall not exceed twenty
percent (20%) of the Agreement Sum. However, the indemnification or compensations for the
IMPAX’s damage or loss resulting from defective Work Products delivered by the Contractor or
from Contractor’s intentional acts or gross negligence are not subject to the maximum
aggregate liability.
	 
	9.6	 	Neither party shall be liable to the other for any loss of profit, loss of use, loss of
production, loss of contracts or for any other indirect or consequential damage that may be
suffered by the other.

-4-

 

	9.7	 	In the event of termination of this Agreement, even if the parties has disagreement about the
termination, Contractor will cooperate with IMPAX to furnish all the requsite documents (e.g.
application of Construction Permit change) to allow IMPAX to continue this Project by itself
or by other contractor.
	 
	9.8	 	In the cases where the period of stopage or suspension of the work successively accumulates
up to six (6) months, either parties may terminate this Agreement by 10 days prior written
notice. IMPAX shall compensate any additional costs, expenses or the like, whether directly
incurred by Contractor if the cause to such stopage or suspension is attribute to IMPAX; and
Contractor shall compensate the same to IMPAX if the situation is vise versa.
	 
	10.	 	FORCE MAJEURE – DELAY BEYOND CONTROL
	 
	10.1	 	The duties and obligations of each of the Parties hereunder shall be suspended during such
time as performance by either Party is prevented or impeded by strikes, labor disturbances,
riots, fire, Governmental action, war, acts of God, or any other cause beyond the reasonable
control of either Party hereto. No such suspension, however, shall affect Contractor’s right
to receive payments of compensation which shall have been already entitled.
	 
	10.2	 	No liability hereunder shall result to either Party from delay in performance or
nonperformance when caused by circumstances beyond the control of the Parties affected. The
Party suffering the Force Majeure shall diligently attempt to remove such cause or causes and
shall promptly notify the other Party of its extent and probable duration.
	 
	10.3	 	If a Party who has delayed performance or not performed on account of these circumstances
beyond its control is unable to remove the causes and recommence performance within seven (7)
days, then the other Party shall have the right to terminate the Agreement, in whole or in
part, without damages imposed.
	 
	11.	 	INDEMNITY
	 
	11.1	 	Each Party, to the extent permitted by law, shall indemnify, defend and hold harmless the
other Party, its affiliated companies, and all of their directors, officers, employees, agents
and representatives from and against all claims, liabilities, damages, losses or expenses to
the extent arising out of any negligence, willful misconduct, breach of contract or violation
of law for which the indemnifying Party, its employees, agents, subcontractors, or assigns in
the performance of Work or Work under the Agreement is at fault or when entering, while on, or
upon leaving the Site. In the event the Parties are jointly at fault, each Party shall
indemnify the other in proportion to its relative fault.
	 
	11.2	 	The claims, liabilities, damages, losses or expenses covered hereunder include, but are not
limited to, settlements, judgments, court costs, attorneys’ fees and other litigation
expenses, fines, and penalties arising out of actual or alleged (a) injury to or death of any
person, including employees of Contractor or IMPAX, or (b) loss of or damage to property,
including property of Contractor or IMPAX, or (c) breach of contract or (d) damage to the
environment.
	 
	11.3	 	If the Contractor is in default in any of its responsibility under this Agreement, IMPAX is
entitled to fulfil the defaulted responsibility on the Contractor’s behalf and claim the cost
or deduct the cost from Performance Bond or Warranty Bond or any payment to the Contractor.

-5-

 

	12.	 	PROPERTY AND RISK
	 
	12.1	 	All Work Product is owned by IMPAX upon creation.
	 
	12.2	 	Contractor irrevocably assigns, transfers and conveys, and shall cause any subcontractors and
other agents of Contractor (and the employees of Contractor and such subcontractors and
agents) to assign, transfer and convey, to IMPAX all of its and their right, title and
interest (including ownership of copyright) in and to all Work Product.
	 
	12.3	 	Contractor warrants: (i) that it has sufficient right, title and interest to assign, transfer
and convey the ownership rights set forth in this Section; and, (ii) that the Work and Work
Product (and use thereof) do not infringe, and shall not infringe or cause the infringement
of, the proprietary rights of any third party.
	 
	12.4	 	Contractor agrees to execute, and shall cause any subcontractors and other agents of
Contractor (and the employees of Contractor and such subcontractors and agents) to execute,
any documents or take any other actions as may reasonably be necessary (or as IMPAX may
reasonably request) to perfect the ownership of IMPAX in the Work Product.
	 
	13.	 	INSURANCE
	 
	 	 	Contractor shall maintain at least the below policies of insurance as necessary for the
Project and such policies shall include IMPAX and sub-subcontractors as co-insured with same
coverage as Contractor. The insurance shall be in force until acceptance of completion of
this Project, and shall be extended if the work schedule is extended.
	 
	 	 	1. Erection All Risk Insurance with a total limit at the
Agreement Sum;

2. Employee Liability Insurance with a total limit at 60 million NT dollars;

3. Third Party Liability Insurance with a total limit at 60 million NT dollars.

	 	 	The cost for the insurance mentioned above is included in the Agreement Sum and therefor the
Contractor shall not ask for reimburecement for the insurance cost. Within 14 business days
after the execution of this Agreement, the Contractor shall provide the insurance documents
to IMPAX.
	 
	14.	 	INDEPENDENT CONTRACTOR
	 
	 	 	The employees, subcontractors, methods, facilities and equipment used by Contractor shall be
at all times under its exclusive direction and control. Contractor’s relationship to IMPAX
under the Agreement shall be that of an independent contractor, and nothing in the Agreement
shall be construed to constitute Contractor, its subcontractors or any of their employees as
an employee, agent, associate, joint venturer, or partner of IMPAX. It is agreed that
Contractor’s employees, who are assigned to IMPAX work under the Agreement, shall at all
times be and remain employees of Contractor.
	 
	15.	 	ASSIGNMENT AND SUBCONTRACTING
	 
	 	 	Neither party shall assign its rights nor delegate performance of its obligations under this
Agreement to any third person, without the prior written consent of the other party, and any
attempted assignment without this consent shall be void.

-6-

 

	 	 	Contractor shall be responsible for any and all acts of its subcontractors, agents, or
assigns in performing Work or works.
	 
	16	 	PERFORMANCE BOND
	 
	16.1	 	Upon the signing of this Agreement, Contractor shall provide with fourteen (14) business
days, a Performance Bond by way of a bank guarantee from a bank approved by IMPAX at an amount
equal to ten percent (10%) of the Agreement Sum, with the validity throughout Work period.
	 
	16.2	 	The cost of obtaining such an all-respect bond shall be born by the Contractor.
	 
	16.3	 	The Contractor shall be responsible for the cost in connection with extending the validity
period inclusive of the maintenance period of the bond in the event the Contractor fails to
complete the Work by the completion date/ extended completion date fixed in the accordance
with the Agreement.
	 
	17.	 	ACCEPTANCE OF THE WORK
	 
	17.1	 	Upon completion of the Work, Contractor shall inform IMPAX in writing for IMPAX’s inspection
and final Acceptance of Contractor’s Work. Within ten (10) business days after receipt of
Contractor’s written notice and depending on the result of IMPAX’s inspection, IMPAX shall
inform Contractor in writing either all the Work have been accepted, or portion of the Work
has been considered not meeting Agreement requirements. IMPAX may chose to accept the
dissatisfactory work, in whole or in part, but decrease the price amount payable for the work
accordingly or negotiate with the Contractor and agree to a schedule for Contractor to make
necessary corrections. However, IMPAX may not grant work schedule extension for the
corrections and Contractor is not free from delay liability hereto. Upon completion of such
corrections, Contractor shall inform IMPAX in writing for inspection. IMPAX shall proceed with
the inspection within ten (10) business days after receipt of such written notice. When all of
the Work is found to be acceptable, final Acceptance procedure/documents have been made, and
the Warranty Bond has been provided by the Contractor, IMPAX shall pay Contractor the
retention payment and return the Performance Bond.
	 
	17.2	 	Unless otherwise specified, if IMPAX fails to provide notice of acceptance or rejection
within the time period mentioned above, the Work shall be deemed to have accepted by IMPAX for
all purpose of this Agreement.
	 
	18.	 	WARRANTY
	 
	18.1	 	Contractor warrants that the Work provided and Work Product delivered shall (i) be free of
defects in material and workmanship; (ii) meet the Scope of Work and all applicable statutory
standards; and (iii) be performed in a safe and workmanlike manner by trained, qualified, and
efficient workers, in strict conformity with best practices.
	 
	18.2	 	The Warranty Period shall be two (2) years, commencing from the day after final Acceptance of
the Work by IMPAX. Contractor shall at its cost, furnish to IMPAX a Warranty Bond, by way of a
bank guarantee from a bank approved by IMPAX at an amount equal to one percent (1%) of the
Agreement Sum, with the validity throughout the Warranty Period.

-7-

 

	18.3	 	In the event a portion of the Work under the Warranty fails to perform its intended
functions, Contractor shall within three (3) days (or, within such reasonable time as agreed
by IMPAX) make good and correct such deficiency at the cost to Contractor. Contractor failure
to take such remedy action constitutes the breach of Warranty and entitled IMPAX to cash the
Warranty Bond.
	 
	18.4	 	The Warranty period for the defect portion shall be extended for a period equals to the
portion that is out of service. In no case however, shall the Warranty be extended beyond
three (3) years after the final Acceptance.
	 
	18.5	 	The Warranty Bond shall return to the Contractor upon the conclusion of Warranty.
	 
	19.	 	DISPUTE RESOLUTION
	 
	19.1	 	Any claims, differences or disputes arising out of or in connection with the present
Agreement including any question regarding its existence, validity termination or its
performance or in connection with arrangements regarding the performance of this Agreement
(hereinafter referred to as “Dispute”) shall be settled by and amicable effort on the part of
the parties by negotiation in the first instance.
	 
	19.2	 	If the parties hereto fail to come to an amicable settlement, the parties agree to be finally
settled by arbitration. The Arbitration shall take place in Taipei according to the
Arbitration Law of the Republic of China.
	 
	19.3	 	The language to be used in the arbitration proceedings shall be Chinese.
	 
	19.4	 	The decision of the arbitrators shall be final and the Parties hereby agree to abide by it.
During the period of arbitration, the performance by both Parties under the Agreement shall be
carried on without interruption and in accordance with the terms hereof, except as to Work for
which IMPAX may specifically authorize delay due to pending arbitration.
	 
	20.	 	NOTICES
	 
	 	 	Any NOTICE required or permitted hereunder shall be deemed to have been sufficiently given to
either Party for all purposes hereof only if given in writing (a) by hand delivery; or (b) by
registered mail or by special delivery; postage prepaid, return receipt requested, addressed
as set forth below, or to such other address as either Party may designate by Notice as
herein requested. All Notices shall be effective upon first receipt. Ordinary project
correspondence between the Parties shall be sent to the same R.O.C. address indicated herein.

	 	 	 	 	 	 	 	 	 
	 	 	TO IMPAX	 	IMPAX Laboratories (Taiwan), Inc.	 	 	 	 
	 
	 	 	 	No. 11, Ke June Rd.	 	 	 	 
	 
	 	 	 	Jhunan 350, Miao-Li, Taiwan	 	 	 	 
	 
	 	 	 	Republic of China	 	 	 	 
	 
	 	 	 	ATTENTION of Project Manager	 	 	 	 
	 
	 	 	 	Fax Number:               (037)  586 558	 	 	 	 
	 
	 	 	 	Telephone Number:         (037)  586 268	 	 	 	 
	 
	 
	 	E&C	 	E&C Engineering Corporation	 	 	 	 
	 
	 	 	 	5F, 16, Lane 270, Pei Shen Rd., Sec. 3,	 	 	 	 
	 
	 	 	 	Shenkeng 222, Taipei, Taiwan	 	 	 	 
	 
	 	 	 	Republic of China	 	 	 	 

-8-

 

	 	 	 	 	 	 	 	 	 
	 	 	 	 	 	 	 	 
	 
	 	 	 	ATTENTION of Project Manager	 	 	 	 
	 
	 	 	 	Fax Number:               (02) 2662-2814, 2664-6102	 	 	 	 
	 
	 	 	 	Telephone Number:         (02) 2662-5858	 	 	 	 

	21.	 	GOVERNING LAW
	 
	 	 	The Agreement including its schedules and any arrangements regarding its performance shall be
governed and construed in accordance with the laws in force in the Republic of China.
	 
	22.	 	AMENDMENT
	 
	 	 	No modification to this Agreement will be binding, unless in writing and signed by a duly
authorised representative of the party to be bound thereby. This applies to the amendment
clause as well.
	 
	23.	 	ENTIRE AGREEMENT
	 
	23.1	 	The Agreement, together with all the attachments specifically referenced, embodies the entire
understanding between IMPAX and Contractor and, except as otherwise specifically stated
herein, there are no contracts, agreements or understandings, oral or written, with reference
to the subject matter hereof which are not merged herein.
	 
	 	 	Attachment A SCOPE OF WORK
	 
	 	 	Attachment B PRICE BREAKDOWN
	 
	23.2	 	If a conflict is determined to exist between the Agreement and its attachments, the following
order of precedence shall be used: (i) the Agreement (exclusive of any attachments thereto);
and (ii) other attachments as listed above.
	 
	23.3	 	The Agreement shall come into effect from the date first shown in this Agreement.

IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed in duplicate by
their duly authorized officers.

	 	 	 	 	 
	IMPAX Laboratories (Taiwan), Inc.

	 	E&C Engineering Corporation
	 	 
	 
	 	 	 	 
	/s/
 Larry Hsu

Mr. Larry Hsu

	 	/s/
Andrew Tsai

Mr. Andrew Tsai
	 	 
	Chairman

	 	President	 	 

-9-

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00155-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00155-of-00352.parquet"}]]