Document:

Exhibit

Section A - Contract Form1
Section B - Supplies or Services/PricesB-1
B.1 DOE-B-2012 Supplies/Services Being Procured/Delivery Requirements (Oct 2014) (Revised)B-1
B.2 Type of ContractB-1
B.3 ORO-B-1001 OBLIGATION OF FUNDS (COST-NO FEE) ALTERNATE IB-2
B.4 DOE-B-1005 Deliverable Requirements – Cost Sharing (Revised)B-2
B.5  Estimated Annual Contract ValueB-3
Section C - Description/SpecificationsC-1
Section D - Packaging and MarkingD-1
D.1 DOE-D-2001 Packaging and Marking (Oct 2014)D-1
D.2  Security RequirementsD-1
Section E - Inspection and AcceptanceE-1
E.1  FAR 52.246-3, Inspection of Supplies – Cost-Reimbursement (May 2001)E-1
E2  FAR 52.246-5, Inspection of Services – Cost Reimbursement (Apr 1984)E-2
Section F - Deliveries or PerformanceF-1
F.1  DOE-F-1001 Delivery ScheduleF-1
F.2  DOE-F-1002 Place of Performance - ServicesF-1
		
	Alternate I (Apr 1984)
	F-1

Section G - Contract Administration DataG-1
G.1  DOE-G-2001 Contracting Officer Authority (Oct 2014)G-1
G.2  DOE-G-2002 Contracting Officer’s Representative (Oct 2014)G-1
G.3  DOE-G-2003 Contractor’s Program Manager (Oct 2014)G-1
G.4  DOE-G-2004 Contract Administration (Oct 2014)G-1
G.5  DOE-G-2005 Billing Instructions – Alternate I (Oct 2014) (Revised)G-3
G.6  DOE-G-2007 Contractor Performance Assessment Reporting (Oct 2014) (Revised)G-5
G.7 DOE-G-2008 Non-Supervision of Contractor Employees (Oct 2014)G-5
Section H - Special Contract RequirementsH-1
H.1  DOE-H-2014 Contractor Acceptance of Notices of Violation or Alleged Violations, Fines, and Penalties (Oct 2014)H-1
H.2  DOE-H-2023 Cost Estimating System Requirements (Oct 2014)H-1
H.3  DOE-H-2025 Accounting System Administration (Oct 2014) (Revised)H-4
H.4  DOE-H-2027 Contractor Property Management System Administration (Oct 2014) (Revised)H-6
H.5  DOE-H-2033 Alternative Dispute Resolution (Oct 2014)H-7
H.6  DOE-H-2038 Nuclear Facilities Operations (Oct 2014)H-8
H.7  DOE-H-2041 Sustainable Acquisition Under Doe Service Contracts (Oct 2014) (Revised)H-9
H.8  DOE-H-2044 Material Safety Data Sheet Availability (Oct 2014)H-10
H.9  DOE-H-2046 Diversity Program (Oct 2014)H-10
H.10  DOE-H-2048 Public Affairs – Contractor Releases Of Information (Oct 2014)H-10
H.11  DOE-H-2049 Insurance Requirements (Oct 2014)H-11
H.12  DOE-H-2052 Representations, Certifications, And Other Statements Of The OfferorH-11
H.13 DOE-H-2056 Annual Indirect Billing Rates (Oct 2014)H-11
H.14  DOE-H-2057 Department Of Labor Wage Determinations (Oct 2014)H-12
H.15  DOE-H-2059 Preservation Of Antiquities, Wildlife And Land Areas (Oct 2014)H-13
H.16  DOE-H-2061 Change Order Accounting (Oct 2014)H-13
H.17  DOE-H-2062 Personal Identity Verification Of Contractor Personnel (Oct 2014)H-13
		
	                  (Oct 2014)
	H-13

		
	 Conference Management (Oct 2014)
	H-14

		
	Key Personnel (Oct 2014) (Revised)
	H-16

		
	Department Of Energy Directives (Oct 2014) (Revised)
	H-16

		
	Prohibition On Funding For Certain Nondisclosure Agreements (Oct 2014)
	H-17

		
	Lobbying Restrictions (Nov 2018)
	H-18

		
	Department Of Energy Training Institute – Occupational Health, Safety, And Emergency Response (Jan 2017)
	H-18

i

		
	Multifactor Authentication For Information Systems
	H-19

		
	greement Regarding Workplace Substance Abuse Programs At Doe Sites        (Apr 2018) (Revised)
	H-19

		
	Workplace Substance Abuse Programs At Doe Sites (Apr 2018)
	H-19

H.28  Emergency ResponseH-20
H.29  Security QualificationsH-20
H.30  DOE-H-2019 Disposition of Intellectual Property – Failure to Complete Contract Performance (Oct 2014) (Revised)H-21
H.31  DOE-H-2021 Work Stoppage and Shutdown Authorization (Oct 2014)H-21
Section I - Contract ClausesI-1
I.1  52.202-1 -- Definitions (Nov 2013)I-1
I.2  52.203-3 – Gratuities (Apr 1984)I-1
I.3  52.203-5 -- Covenant Against Contingent Fees (May 2014)I-2
I.4  52.203-6 -- Restrictions on Subcontractor Sales to the Government (Sep 2006)I-2
I.5  52.203-7 -- Anti-Kickback Procedures (May 2014)I-3
		
	     (May 2014)
	I-4

I.7  52.203-10 -- Price or Fee Adjustment for Illegal or Improper Activity (May 2014)I-5
I.8  52.203-12 -- Limitation on Payments to Influence Certain Federal Transactions (Oct 2010)I-6
I.9  52.203-13 – Contractor Code of Business Ethics and Conduct (Oct 2015)I-11
I.10  52.203-14 – Display of Hotline Poster(s) (Oct 2015)I-16
		
	     Employees of Whistleblower Rights (Apr 2014)
	I-17

		
	      Statements (Jan 2017)
	I-17

I.13 52.204-4 -- Printed or Copied Double-Sided on Postconsumer Fiber Content Paper (May 2011)I-18
I.14  52.204-9 -- Personal Identity Verification of Contractor Personnel (Jan 2011)I-19
		
	                 (Oct 2018)
	I-19

I.16  52.204-13 – System for Award Management Maintenance (Oct 2018)I-23
I.17  52.204-14 – Service Contract Reporting Requirements (Oct 2016)I-26
I.18  52.204-18 Commercial and Government Entity Code Maintenance (Jul 2016)I-27
I.19  52.204-19 – Incorporation by Reference of Representations and Certifications (Dec 2014)I-28
I.20 FAR 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (Jun 2016)    I-28
I.21  52.204-23-Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018)I-30
		
	   Debarred, Suspended, or Proposed for Debarment (Oct 2015)
	I-31

I.23  52.209-9 – Updates of Publicly Available Information Regarding Responsibility Matters (Oct 2018)I-33
I.24  52.209-10 – Prohibition on Contracting With Inverted Domestic Corporations (Nov 2015)I-34
I.25  52.210-1 Market Research (Apr 2011)I-34
I.26  52.215-2 -- Audit and Records – Negotiation (Oct 2010)I-35
I.27  52.215-8 -- Order of Precedence -- Uniform Contract Format (Oct 1997)I-37
I.28  52.215-10 -- Price Reduction for Defective Certified Cost or Pricing Data (Aug 2011)I-37
		
	       (Aug 2011)
	I-39

I.30  52.215-12 Subcontractor Certified Cost or Pricing Data (Deviation 2018-O0015) (MAY 2018)I-41
I.31  52.215-13 Subcontractor Certified Cost or Pricing Data–Modifications (Deviation 2018-O0015) (MAY 2018)I-42
I.32  52.215-14 -- Integrity of Unit Prices (Oct 2010)I-43
I.33  52.215-15 -- Pension Adjustments and Asset Reversions (Oct 2010)I-43
I.34  52.215-17 -- Waiver of Facilities Capital Cost of Money (Oct 1997)I-44

ii

I.35  52.215-18 -- Reversion or Adjustment of Plans for Postretirement Benefits (PRB) Other Than Pensions (Jul 2005)I-44
I.36  52.215-19 -- Notification of Ownership Changes (Oct 1997)I-44
		
	    Cost or Pricing Data – Modifications (Oct 2010)
	I-45

I.38  52.215-23 – Limitations on Pass-Through Charges (Oct 2009)I-47
I.39  52.216-7 -- Allowable Cost and Payment (Aug 2018)I-49
I.40  52.216-12 -- Cost-Sharing Contract -- No Fee (Apr 1984)I-56
I.41  52.219-6   Notice of Total Small Business Set-Aside (Nov 2011)I-57
I.42  52.219-14 Limitations on Subcontracting (Jan 2017)I-58
I.43  52.219-28 Post-Award Small Business Program Rerepresentation (Jul 2013)I-58
I.44  52.219-8 -- Utilization of Small Business Concerns (Oct 2018)I-60
I.45  52.222-1 -- Notice to the Government of Labor Disputes (Feb 1997)I-63
I.46  52.222-2 -- Payment for Overtime Premiums (Jul 1990)I-63
I.47  52.222-3 -- Convict Labor (June 2003)I-64
I.48  52.222-4 -- Contract Work Hours and Safety Standards -- Overtime Compensation (May 2018)I-65
I.49  52.222-6 – Construction Wage Rate Requirements (Aug 2018)I-66
I.50  52.222-7 -- Withholding of Funds (May 2014)I-69
I.51  52.222-8 -- Payrolls and Basic Records (Aug 2018)I-70
I.52  52.222-9 -- Apprentices and Trainees (Jul 2005)I-71
I.53  52.222-10 -- Compliance with Copeland Act Requirements (Feb 1988)I-73
I.54  52.222-11 -- Subcontracts (Labor Standards) (May 2014)I-74
I.55  52.222-12 -- Contract Termination – Debarment (May 2014)I-75
I.56  52.222-13 -- Compliance with Construction Wage Rate Requirements and Related Regulations (May 2014)I-75
I.57  52.222-14 -- Disputes Concerning Labor Standards (Feb 1988)I-76
I.58  52.222-15 -- Certification of Eligibility (May 2014)I-76
I.59  52.222-16 -- Approval of Wage Rates (May 2014)I-76
I.60  52.222-21 -- Prohibition of Segregated Facilities (Apr 2015)I-76
I.61  52.222-26 -- Equal Opportunity (Sep 2016)I-77
I.62 FAR 52.222-35, Equal Opportunity for Veterans (OCT 2015)    I-81
I.63 FAR 52.222-36, Equal Opportunity for Workers with Disabilities (JUL 2014)    I-81
I.64  52.222-37 -- Employment Reports on Veterans (Feb 2016)I-82
		
	              (Dec 2010)
	I-83

I.66  52.222-41 -- Service Contract Labor Standards (Aug 2018)I-84
I.67FAR 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014)    I-92
		
	     Adjustment (Multiple Year and Option Contracts (Aug 2018)
	I-93

I.69  52.222-50 -- Combating Trafficking in Persons (Jan 2019)I-94
I.70  52.222-54 – Employment Eligibility Verification (Oct 2015)I-104
I.71  52.222-55 -- Minimum Wages Under Executive Order 13658 (Dec 2015)I-108
I.72  52.222-62 Paid Sick Leave Under Executive Order 13706 (JAN 2017)I-113
I.73  52.223-2 -- Affirmative Procurement of Biobased Products Under Service And Construction Contracts (Sep 2013)I-120
I.74  52.223-3 -- Hazardous Material Identification and Material Safety Data (Jan 1997)I-121
I.75  52.223-5 -- Pollution Prevention and Right-to-Know Information (May 2011)I-122
I.76  52.223-6 -- Drug-Free Workplace (May 2001)I-123
I.77FAR 52.223-7, Notice of Radioactive Materials (Jan 1997)    I-125
I.78FAR 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (May 2008)    I-126
I.79  52.223-10 -- Waste Reduction Program (May 2011)I-126
I.80  52.223-13 – Acquisition of EPEAT® - Registered Imaging Equipment (Jun 2014)I-127

iii

I.81  52.223-14 – Acquisition of EPEAT® -Registered Televisions (Jun 2014)I-128
I.82  52.223-15 – Energy Efficiency in Energy-Consuming Products (Dec 2007)I-129
I.83  52.223-16 – Acquisition of EPEAT®-Registered Personal Computer Products (Oct 2015)I-130
I.84  52.223-17 – Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts (Aug 2018)I-131
		
	                (Aug 2011)
	I-132

I.86  52.223-19 -- Compliance with Environmental Management Systems (May 2011)I-133
I.87  52.223-20 – Aerosols (Jun 2016)I-133
I.88  52.223-21 -- Foams (Jun 2016)I-134
I.89  52.224-1 -- Privacy Act Notification (Apr 1984)I-134
I.90  52.224-2 -- Privacy Act (Apr 1984)I-134
I.91  52.225-1 -- Buy American—Supplies (May 2014)I-136
I.92 52.225-9 -- Buy American–Construction Materials (May 2014)I-137
I.93  52.225-11, Buy American – Construction Materials Under Trade Agreements (Oct 2016)I-141
I.94  52.225-13 -- Restrictions on Certain Foreign Purchases (Jun 2008)I-146
I.95  52.227-1 -- Authorization and Consent (Dec 2007)I-146
I.96  52.227-2 -- Notice and Assistance Regarding Patent and Copyright Infringement (Dec. 2007)I-147
I.97  52.227-3 -- Patent Indemnity (Apr 1984)I-147
I.98  52.227-10 -- Filing of Patent Applications -- Classified Subject Matter (Dec 2007)I-148
I.99  52.227-16 -- Additional Data Requirements (Jun 1987)I-149
I.100  52.228-5 -- Insurance -- Work on a Government Installation (Jan 1997)I-149
I.101  52.232-11 -- Extras (Apr 1984)I-150
I.102  52.232-9 -- Limitation on Withholding of Payments (Apr 1984)I-150
I.103  52.232-17 -- Interest (May 2014)I-150
I.104  52.232-22 -- Limitation of Funds (Apr 1984)I-152
I.105  52.232-23 -- Assignment of Claims (May 2014)I-154
I.106 52.232-25 -- Prompt Payment (Jan 2017)I-155
		
	            (Oct 2018)
	I-161

I.108  52.232-39 – Unenforceability of Unauthorized Obligations (Jun 2013)I-163
I.109  52.232-40 – Providing Accelerated Payments to Small Business Subcontractors (Dec 2013)I-163
I.110  52.233-1 -- Disputes (May 2014)I-164
I.111  52.233-3 -- Protest After Award (Aug. 1996)I-165
I.112  52.233-4 -- Applicable Law for Breach of Contract Claim (OCT 2004)I-166
I.113  52.236-5 -- Material and Workmanship (Apr 1984)I-166
I.114  52.239-1 -- Privacy or Security Safeguards (Aug. 1996)I-167
I.115  52.242-1 -- Notice of Intent to Disallow Costs (Apr 1984)I-167
I.116  52.242-3 -- Penalties for Unallowable Costs (May 2014)I-168
I.117  52.242-4 -- Certification of Final Indirect Costs (Jan 1997)I-169
I.118  52.242-13 -- Bankruptcy (Jul 1995)I-170
I.119  52.243-2 -- Changes -- Cost-Reimbursement (Aug 1987) (Alt I)I-170
I.120  52.243-6 -- Change Order Accounting (Apr 1984)I-171
I.121  52.243-7 -- Notification of Changes (Jan 2017)I-171
I.122  52.244-2 -- Subcontracts (Oct 2010)I-174
I.123 52.244-5 -- Competition in Subcontracting (Dec 1996)I-176
I.124  52.244-6 -- Subcontracts for Commercial Items (Jan 2019)I-177
I.125  52.245-1 -- Government Property (Jan 2017)I-179
I.126  52.245-9 -- Use and Charges (Apr 2012)I-195
I.127  52.246-25 -- Limitation of Liability – Services (Feb 1997)I-197
I.128  52.247-1 -- Commercial Bill of Lading Notations (Feb 2006)I-198
I.129  52.247-63 -- Preference for U.S.-Flag Air Carriers (June 2003)I-199
I.130  52.249-6 -- Termination (Cost-Reimbursement) (May 2004)I-200
I.131  52.249-14 -- Excusable Delays (Apr 1984)I-204

iv

I.132  52.251-1 -- Government Supply Sources (Apr 2012)I-205
I.133  52.253-1 -- Computer Generated Forms (Jan 1991)I-205
I.134  952.202-1 Definitions (Feb 2011)I-206
I.135  952.203-70 Whistleblower Protection for Contractor Employees (DEC 2000)I-206
I.136  952.204-2 Security Requirements (Aug. 2016)I-206
I.137  952.204-70 Classification/Declassification (SEP 1997)I-210
I.138  952.204-75  Public Affairs (DEC 2000)I-211
I.139  952.204-77 Computer Security (AUG 2006)I-212
I.140  952.208-70 Printing (APR 1984)I-213
I.141  952.215-70 Key Personnel (DEC 2000)I-214
		
	                  (APR 1984)
	I-214

I.143  952.223-78 Sustainable Acquisition Program (OCT 2010)I-214
I.144  952.226-71 Utilization of Energy Policy Act Target Entities (JUN 1996)I-217
		
	                 (JUN 1996)
	I-217

I.146  952.226-74 Displaced Employee Hiring Preference (JUN 1997)I-219
I.147  952.227-13 Patent Rights—Acquisition by the Government (SEP 1997)I-219
		
	.148  952.231-71 Insurance—Litigation and Claims (JUL 2013)
	I-230

I.149  952.242-70 Technical Direction (DEC 2000)I-231
I. 150  952.250-70 Nuclear Hazards Indemnity Agreement (AUG 2016)I-233
I.151  952.247-70 Foreign Travel (JUN 2010)I-236
I.152  952.251-70 Contractor Employee Travel Discounts (AUG 2009)I-236
I.153  970.5204-1 Counterintelligence (DEC 2010)I-237
I.154  970.5227-1 Rights in Data—Facilities (DEC 2000)I-238
I.155  52.216-24 -- Limitation of Government Liability (Apr 1984)I-244
I.156  52.216-25 -- Contract Definitization (Oct 2010)I-244
I.157  52.216-26 -- Payments of Allowable Costs Before Definitization (Dec. 2002)I-245
I.158  52.232-16 Progress Payments (Apr 2012)I-247
Section J - List of Documents, Exhibits and Other AttachmentsJ-1
DOE-J-1001 List of AttachmentsJ-1

v

Section A - Contract Form

Section B - Supplies or Services/Prices

B.1 DOE-B-2012 Supplies/Services Being Procured/Delivery Requirements (Oct 2014) (Revised)
The Contractor shall furnish all personnel, facilities, equipment, material, supplies, and services (except as may be expressly set forth in this contract as furnished by the Government) and otherwise do all things necessary for, or incidental to, the performance of work as described in Section C, Performance Work Statement (PWS).

B.2 Type of Contract
		
	(a)
	This is a performance-based contract that includes cost-reimbursement-no-fee contract line items (CLINs).  While the CLIN and subCLIN amounts annotated below are estimated costs, the total Government share of $115,000,000 is considered to be a ceiling price.

		
	(b)
	The contract consists of the CLINs shown in Table B.2-1:

Table B.2-1. Contract CLIN Structure

	
						
	CLIN
	Title
	Total Estimated Cost
	Estimated Cost
	PWS Section

	1
	EPC
	 
	 
	Section C.1

	1.1
	Design and Engineering
	 
	 
	Section C.1

	1.2
	Procurement
	 
	 
	Section C.1

	1.3
	Construction
	 
	 
	Section C.1

	00001.3.1
	CTTF Refurbishment
	 
	 
	Section C.1

	00001.3.2
	Cascade/BOP Construction
	 
	 
	Section C.1 - Milestone 7

	00001.3.3
	Contaminated Equipment Installation
	 
	 
	Section C.1

	00001.3.4
	Construction Commissioning
	 
	 
	Section C.1

	00001.3.5
	Physical Security Modifications
	 
	 
	Section C.1

	00001.3.6
	IST Support
	 
	 
	Section C.1

	1.4
	Project Management
	 
	 
	Section C.1

	2
	Manufacturing
	 
	 
	Section C.1

	2.1
	Machine Controls
	 
	 
	Section C.2

	2.2
	LSA
	 
	 
	Section C.2

	2.3
	USA
	 
	 
	Section C.2

	2.4
	Column
	 
	 
	Section C.2

	2.5
	Casing
	 
	 
	Section C.2 – Milestone 3

	2.6
	Rotor Balancing
	 
	 
	Section C.2

	2.7
	Other Parts
	 
	 
	Section C.2

	2.8
	Transportation
	 
	 
	Section C.2 - Milestone 6b

	2.9
	Project Management
	 
	 
	Section C.2

	3
	Plant Support and Cascade Startup/Operations
	 
	 
	Section C.3

	3.1
	Facility Preparation for Project
	 
	 
	Section C.3

	3.2
	Machine Assembly and Drying
	 
	 
	Section C.3 – Milestone 8

	3.3
	Machine Installation, Startup, IRR, ORR
	 
	 
	Section C.3 – Milestones 9 and 10

	3.4
	Operations
	 
	 
	Section C.3 – Milestones 12, 13, and 14

	3.5
	Balance of Plant Operations
	 
	 
	Section C.3

	3.6
	Project Management
	 
	 
	Section C.3

	4
	Regulatory Support
	 
	 
	Section C.4

	4.1
	Licensing
	 
	 
	Section C.4 – Milestones 1 and 11

	4.2
	Safeguards and Security
	 
	 
	Section C.4 - Milestone 5

	4.3
	ISA/NCSA
	 
	 
	Section C.4

	4.4
	Permitting
	 
	 
	Section C.4

	5
	HALEU Program Management
	 
	 
	Section C.5– Milestones 2, 4 and 6a

	Total DOE Cost
	 
	 

	Contractor Cost Share
	 
	 

	Total Estimated Contract Value
	 
	 

B.3 ORO-B-1001 OBLIGATION OF FUNDS (COST-NO FEE) ALTERNATE I
Pursuant to the clause entitled "Limitation of Funds," $18,600,000 is obligated and $6,400,000 is available for payment of allowable costs to be incurred from the effective date of this contract through the period estimated to end [TBD].

B.4 DOE-B-1005 Deliverable Requirements – Cost Sharing (Revised)

(a) This is a cost sharing, no fee type of contract. In accordance with the clause at FAR 52.216-12, Cost-Sharing Contract-No Fee, the total estimated contract value and cost-sharing ratios are as follows:

Total Contract Estimated Contract Value _____ 

Government’s Share _____   [80%]

Contractor's Share _____  [20%]

(b) The Total Estimated Value of the contract, and/or the Total Estimated Value of the Contract Line Items, is as follows:
 _________________ 

(c) The Contractor’s share shall not have been reimbursed by the Federal Government under any other agreement with the Federal Government, including but not limited to, contracts, subcontracts at any tier, work authorizations under a DOE lease, or financial assistance agreements.

B.5  Estimated Annual Contract Value
DOE expects to obligate funding to the contract according to the estimated annual contract value:
Table B.5-1. Estimated Annual Contract Value

	
			
	Government Fiscal Year (FY)
	 
	Estimated Cost

	FY 2019
	 
	$35M

	FY 2020
	 
	$40M

	FY 2021
	 
	$40M

Funding for the Contract is subject to the appropriations of Congress.  It is not guaranteed that the funding will be provided or obligated in the amounts stated.  If DOE does not receive appropriated funds in accordance with the amounts shown in the table above, the amounts will be adjusted via modification to the contract.

Section C - Description/Specifications

High Assay Low Enriched Uranium (HALEU) Demonstration Project

Project Objectives

The objective of the HALEU Demonstration Program is to demonstrate the capability to produce HALEU with existing US origin enrichment technology, and provide DOE with HALEU for near term use in its research and development for the advancement of civilian nuclear energy and security, and other programmatic missions. While DOE will retain title to the HALEU produced, DOE is amenable to make it available to the Contractor for DOE R&D purposes.  This demonstration consists of the deployment of a 16 machine AC100M HALEU Cascade to be located at DOE’s site in Piketon, Ohio, producing a 19.75% U235 enriched product by April 1, 2022. In order to fulfill these objectives, the Project will accomplish 14 defined Milestones.  The Milestones to be completed by the Contractor are:

MILESTONE 1 - Rescind the License Amendment Request (License Number SNM-7003) to the Nuclear Regulatory Commission (NRC) for removal of enrichment as an authorized activity and for downgrade of licensed activities for the Lead Cascade by July 1, 2019.  This activity is considered complete when the Contractor’s letter is submitted to the NRC.  

MILESTONE 2 - Re-establish required site services under the Memorandum of Agreement for the Supply of Services (Exhibit F of GCEP Lease) by January 1, 2020.

MILESTONE 3 - Procure machine casings: 
		
	a)
	Award sub-contract to procure machine casings by August 1, 2019.

MILESTONE 4 - Re-establish vendor supply chain(s) of materials and equipment necessary for deployment and production of unobligated HALEU by June 1, 2020. 

MILESTONE 5- Re-constitute the security program to support possession of C-24 technology and assembly/installation/operation of the HALEU Cascade at the DOE leased facilities located in Piketon, Ohio by November 1, 2020. 
		
	a)
	Obtain Security Plan approval from NRC.

		
	b)
	Modify and implement Security Plan procedures.

		
	c)
	Request security clearances for new personnel.

MILESTONE 6 - Deliver sub-assemblies for 16 AC100M machines (Drawing no. 1007800 
Rev. 0) to the DOE leased facilities located in Piketon, Ohio: 
		
	a)
	Transfer title of Contractor-owned machine components to DOE by September 1, 2019.

		
	b)
	Deliver sub-assemblies for 16 AC100M machines to DOE leased facilities in Piketon, Ohio by December 15, 2020.

MILESTONE 7 - Complete reconstitution of HALEU Balance of Plant (BOP) and cascade infrastructure (e.g., utilities, controls, service module) by November 1, 2021.

MILESTONE 8 – Assemble and dry 16 AC100M machines for the HALEU cascade by November 1, 2021. 

MILESTONE 9 - Install 16 AC100M machines for the HALEU cascade by December 1, 2021.

MILESTONE 10 - Complete operational readiness for operation of the HALEU Cascade on UF6 gas by March 1, 2022.

MILESTONE 11 - Obtain an NRC license revision for the Combined License (COL) to support production of 19.75% U235 by March 1, 2022.

MILESTONE 12 - Initiate operation of the HALEU 16 AC100M machine cascade by March 1, 2022.

MILESTONE 13 - Operate the HALEU Cascade on UF6 and produce a nominal 19.75%  0.24% U235 Pinch Tube or P-10 sample(s) by March 15, 2022.

MILESTONE 14 – Operate the HALEU Cascade to produce up to 600 Kg UF6 of HALEU by no later than Jun 1, 2022.

Project Scope

The Project will support the following major areas of activity and any other necessary activities to complete the Objectives and Milestones described in Section C.1.1:
		
	•
	Engineering/Procurement/Construction (EPC) of the HALEU Cascade

		
	•
	Manufacturing of the AC100M Components and Subassemblies

		
	•
	Plant Support and Cascade Startup/Operations 

		
	•
	Regulatory Support

		
	•
	HALEU Program Management

Each major activity area is described separately as follows:

C.1 Engineering/Procurement/Construction (EPC) of the HALEU Cascade

EPC activities will include all the engineering, procurement and construction associated with reconstituting the Balance of Plant (BOP) and cascade components and systems to support the HALEU Cascade at Piketon, Ohio, including the vacuum, air, chilled water, and electrical systems and associated instrumentation and controls; the emergency power system; the distributed control system; the feed and withdrawal modules; the mass spectrometer, and the service module.  Included also, are CTTF refurbishment; vent monitoring and centrifuge conditioning systems; and physical security modifications. Construction commissioning and Integrated System Test support is included. Also included is Project management of the EPC activities. 

C.2 Manufacturing (AC100M Components and Subassemblies)

Manufacturing activities will include all associated procurement and manufacturing of machine parts, components and subassemblies of the AC100M machines for the HALEU cascade, including the machine controls, upper and lower suspension, column, casing, and rotors (including balancing).  Transportation of the manufactured items to Piketon, Ohio is included as well as project management of the Manufacturing activities.  

C.3 Plant Support and Cascade Startup/Operations 

Plant Support activities include all preparation of the facility for installation of the HALEU 16-machine cascade, assembly and drying of the AC100M centrifuges, and installation and tie-ins of the machines to complete the HALEU cascade configuration.  Cascade Startup/Operation activities include the Internal Readiness Review, the Operational Readiness Review, cascade startup and operation (including maintenance), and production of the nominal 19.75% U235 sample and product up to 600 Kg. Also included is project management of the activities.   Maintain and operate Balance of Plant (BOP) facilities.

C.4 Regulatory Support

Regulatory Support activities include NRC licensing, safeguards and security, Integrated Safety Analysis/Nuclear Criticality Safety Analysis, and permitting.

C.5 HALEU Program Management

Program Management will provide overall project direction of all activities and participants and management of the project including establishing a project Work Breakdown Structure (WBS) and baseline against which, performance will be measured using an earned value management system.  The Contractor shall develop and provide a WBS that aligns with Contractor activities sequencing and execution of the HALEU Demonstration Program. Also, the Contractor shall develop and provide an integrated logic driven critical path schedule reflecting the WBS and which identifies contract milestones and deliverables. Formal status reports and meetings will be provided and held monthly with DOE to report and discuss schedule progress, milestone performance, cost performance, any variances, any concerns, and to identify action items. The Contractor will develop an agenda for these meetings and submit it to DOE at least seven (7) calendar days prior to the meeting. The meeting location will be mutually agreed upon between the Contractor and DOE. In addition, reports will be prepared and submitted to DOE to provide evidence of completion of project milestones. In addition, a weekly highlights report shall be provided electronically.  Ad hoc meetings or conversations with DOE outside any formal meetings are to be utilized in a timely manner to identify and address any potential problems and concerns. Program Management will conduct activities that reduce overall risk to the project and assure a robust quality assurance program is implemented across the project.

American Centrifuge Operating, LLC (ACO) utilizes a fully integrated Earned Value Management System (EVMS) in the execution of capital projects.  ANSI/EIA-748-B Earned Value Management Systems and the GAO Cost Estimating and Assessment Guide serve as the basis for the ACO EVM System.  
The system includes: Primavera P6 as the scheduling platform, Project Management Cost Processor (PMCP) as the cost processing, reporting and change control platform, Primavera Risk as the probabilistic risk analysis platform, and Oracle as the corporate financial system.
Major components of the system include:
		
	•
	Integrated scope, cost and schedule Performance Measurement Baselines (PMB)

		
	•
	Critical Path Methodology (CPM) used in evaluating schedule performance

		
	•
	Probabilistic Risk Assessment (PRA) used in calculating project risks

		
	•
	Formal change control process for both baselines and forecasts

		
	•
	Monthly re-forecasting of project TEC and schedule

The EVM System and Project Controls are implemented and controlled at the corporate level of ACO and Centrus Energy Corp. ensuring continuity and consistency of its application across all projects in the Contractor’s project portfolio. 

C.6  Special Conditions

		
	1.
	The Contractor will provide the U.S.-origin UF6 feed stock for production of the nominal 19.75% U235 material identified in Milestone 14.

		
	2.
	In the performance of this Contract, the Contractor will abide by all conditions and requirements included in the Access Permit No. 11-04: AC Operating, which includes any approved revisions. In the event that any requirements in the Contract conflict with the Access Permit, the Contractor shall comply with the Access Permit and immediately notify the Contracting Officer.  

		
	3.
	The Contractor will provide evidence of certification of unobligated U.S. source fiber vendor(s) to be used in the AC100M.  Note: unobligated source fiber is not a requirement for this demonstration project.

		
	4.
	Any incremental additional cost associated with transition to a secure facility prior to December 1, 2020 will be included as contractor cost share.  In addition, the Contractor shall obtain DOE approval prior to introducing uranium material to the Piketon site.  

		
	5.
	The Contractor is the sublessee of the Lease Agreement Between DOE and the United States Enrichment Corporation dated December 7, 2006 (GCEP Lease).  DOE has agreed that the Lessee has satisfied the GCEP Lease turnover conditions, except for compressors and one generator which will be made operable as identified in Condition Reports X-6000 and X-3001.  In no event will the Contractor charge to this Contract, whether as a direct or indirect charge, or as a credit for cost share, any costs associated with labor, equipment, supplies or any other costs required for the Lessee to comply with the Lease turnover requirements, nor shall the Contractor charge this Contract, whether as a director or indirect charge, or as a credit for cost share, for any services required prior to fulfillment of these turnover requirements that would not otherwise have been necessary. 

Section D - Packaging and Marking

D.1 DOE-D-2001 Packaging and Marking (Oct 2014)
		
	(a)
	Preservation, packaging and packing for shipment, and mailing of all work delivered hereunder shall be in accordance with good commercial practice and adequate to insure acceptance by common carrier and safe transportation at the most economical rate(s), including electronic means.

		
	(b) 
	Each package, report, or other deliverable shall be accompanied by a letter or other document which:

		
	(1) 
	Identifies the contract by number pursuant to which the item is being delivered;

		
	(2) 
	Identifies the deliverable item number or report requirement which requires the delivered item; and

		
	(3) 
	Indicates whether the Contractor considers the delivered item to be a partial or full satisfaction of the requirement.

		
	(c) 
	For any package, report, or other deliverable being delivered to a party other than the Contracting Officer, a copy of the document required by paragraph (b) shall be simultaneously delivered to the office administering this contract as identified in Section G of the contract or, if none, to the Contracting Officer.

D.2  Security Requirements
The Contractor shall comply with the security requirements for packaging, marking, mailing, and shipping classified materials (if any) as prescribed by applicable NRC regulations, specifically the Standard Practice Procedures Plan:  Standard Format and Common Set of Requirements for the Protection of Classified Matter for USEC Inc. and Its Limited Liability Companies Regulated by the U.S. Nuclear Regulatory Commission, dated March 2011 (as agreed upon by DOE and NRC).

Section E - Inspection and Acceptance

E.1  FAR 52.246-3, Inspection of Supplies – Cost-Reimbursement (May 2001)
		
	(a)
	Definitions.  As used in this clause,

“Contractor’s managerial personnel” means any of the Contractor’s directors, officers, managers, superintendents, or equivalent representatives who have supervision or direction of:
		
	(1)
	All or substantially all of the Contractor’s business;

		
	(2)
	All or substantially all of the Contractor’s operation at a plant or separate location where the Contract is being performed; or

		
	(3)
	A separate and complete major industrial operation connected with performing this Contract.

“Supplies” include but is not limited to raw materials, components, intermediate assemblies, end products, lots of supplies, and, when the Contract does not include the Warranty of Data clause, data.
		
	(b)
	The Contractor shall provide and maintain an inspection system acceptable to the Government covering the supplies, fabricating methods, and special tooling under this Contract.  Complete records of all inspection work performed by the Contractor shall be maintained and made available to the Government during Contract performance and for as long afterwards as the Contract requires. 

		
	(c)
	The Government has the right to inspect and test the Contract supplies, to the extent practicable at all places and times, including the period of manufacture, and in any event before acceptance.  The Government may also inspect the plant or plants of the Contractor or any subcontractor engaged in the Contract performance.  The Government shall perform inspections and tests in a manner that will not unduly delay the work. 

		
	(d)
	If the Government performs inspections or tests on the premises of the Contractor or a subcontractor, the Contractor shall furnish and shall require subcontractors to furnish all reasonable facilities and assistance for the safe and convenient performance of these duties. 

		
	(e)
	Unless otherwise specified in the Contract, the Government shall accept supplies as promptly as practicable after delivery, and supplies shall be deemed accepted 60 days after delivery, unless accepted earlier.

		
	(f)
	At any time during Contract performance, but no later than six (6) months (or such other time as may be specified in the Contract) after acceptance of the supplies to be delivered under the Contract, the Government may require the Contractor to replace or correct any supplies that are nonconforming at time of delivery.  Supplies are nonconforming when they are defective in material or workmanship or are otherwise not in conformity with Contract requirements.  Except as otherwise provided in paragraph (h) of this clause, the cost of replacement or correction shall be included in allowable cost, determined as provided in the Allowable Cost and Payment clause, but no additional fee shall be paid. The Contractor shall not tender for acceptance supplies required to be replaced or corrected without disclosing the former requirement for replacement or correction and, when required, shall disclose the corrective action taken.

		
	(g)
	

(1)  If the Contractor fails to proceed with reasonable promptness to perform required  
       replacement or correction, the Government may:
		
	(i)
	By Contract or otherwise, perform the replacement or correction and charge to the Contractor any increased cost, or make an equitable reduction in any fixed fee paid or payable under the Contract;

(ii)Require delivery of undelivered supplies at an equitable reduction in any fixed fee paid or payable under the Contract; or 
(iii)Terminate the Contract for default.
		
	(2)
	Failure to agree on the amount of increased cost to be charged to the Contractor or to the reduction in the fixed fee shall be a dispute.

		
	(h)
	Notwithstanding paragraphs (f) and (g) of this clause, the Government may, at any time, require the Contractor to correct or replace, without cost to the Government, nonconforming supplies, if the non‐conformances are due to:

		
	(1)
	Fraud, lack of good faith, or willful misconduct on the part of the Contractor’s managerial personnel; or

		
	(2)
	The conduct of one or more of the Contractor’s employees selected or retained by the Contractor after any of the Contractor’s managerial personnel has reasonable grounds to believe that the employee is habitually careless or unqualified.

		
	(i)
	This clause applies in the same manner to corrected or replacement supplies as to supplies originally delivered.

		
	(j)
	The Contractor shall have no obligation or liability under this Contract to replace supplies that were nonconforming at the time of delivery, except as provided in this clause or as may be otherwise provided in the Contract. 

		
	(k)
	Except as otherwise specified in the Contract, the Contractor’s obligation to correct or replace Government furnished property shall be governed by the clause pertaining to Government property.

E2  FAR 52.246-5, Inspection of Services – Cost Reimbursement (Apr 1984)
		
	(a)
	Definition.  “Services,” as used in this clause, includes services performed, workmanship, and material furnished or used in performing services.

		
	(b)
	The Contractor shall provide and maintain an inspection system acceptable to the Government covering the services under this Contract.  Complete records of all inspection work performed by the Contractor shall be maintained and made available to the Government during Contract performance and for as long afterwards as the Contract requires. 

		
	(c)
	The Government has the right to inspect and test all services called for by the Contract, to the extent practicable, at all places and times during the term of the Contract.  The Government shall perform inspections and tests in a manner that will not unduly delay the work. 

		
	(d)
	If any of the services performed do not conform with Contract requirements, the Government may require the Contractor to perform the services again, in conformity with Contract requirements, for no additional fee.  When the defects in services cannot be corrected by re-performance, the Government may:

		
	(1)
	Require the Contractor to take necessary action to ensure that future performance conforms to Contract requirements; and

		
	(2)
	Reduce any fee payable under the Contract to reflect the reduced value of the services performed.

		
	(e)
	If the Contractor fails to promptly perform the services again or take the action necessary to ensure future performance in conformity with Contract requirements, the Government may: 

		
	(1)
	By Contract or otherwise, perform the services and reduce any fee payable by an amount that is equitable under the circumstances; or

		
	(2)
	Terminate the Contract for default. 

Section F - Deliveries or Performance

F.1  DOE-F-1001 Delivery Schedule 
The Government requires delivery to be made according to the following schedule:

	
			
	MILESTONE
	Title
	Date

	1
	Rescind the NRC Lead Cascade License Amendment
	July 1, 2019

	2
	Reestablish Site Services to support the HALEU Program at Piketon
	January 1. 2020

	00003a
	Award Sub-Contract to Procure Machine Casings
	August 1, 2019

	00003b
	Receive Machine Casings 1-6
	[To Be Proposed]

	00003c
	Receive Machine Casings 7-12
	[To Be Proposed]

	00003d
	Receive Machine Casings 13-18
	[To Be Proposed]

	4
	Reestablish the Vendor Supply Chain to Support the HALEU Program
	TBD

	00005a,b,c
	Reconstitute the Security Program for the Piketon Facilities
	December 1, 2020

	00005d
	“Stand up” facility for possession of C-24 technology
	No Earlier Than December 1, 2020

	00006a
	Transfer Title of Contractor-Owned Machine Components to DOE
	September 1, 2019

	00006b
	Deliver AC100M Subassemblies to Piketon
	February 3, 2021

	7
	Complete Reconstitution of HALEU BOP and Cascade Infrastructure
	November 1, 2021

	8
	Assemble and Dry 16 AC100M Machines
	November 1, 2021

	9
	Install 16 AC100M Machine in the HALEU Cascade
	December 1, 2022

	10
	Complete Operational Readiness for the HALEU Cascade
	March 1,2022

	11
	Obtain NRC License Revision for COL
	March 1, 2022

	12
	Initiate Operation of the HALEU Cascade
	March 1, 2022

	13
	Operate the HALEU Cascade and Produce 19.75% U235Sample
	March 15, 2022

	14
	Operate the HALEU Cascade and Produce 19.75% U235 Material
	June 1, 2022

F.2  DOE-F-1002 Place of Performance - Services     
The services specified by this contract shall be performed at the following location (s): Contractor’s Facilities and the DOE Site in Piketon, Ohio.  

F.3  52.242-15  Stop-Work Order (Aug. 1989)  Alternate I (Apr 1984)
(a) The Contracting Officer may, at any time, by written order to the Contractor, require the Contractor to stop all, or any part, of the work called for by this contract for a period of 90 days after the order is delivered to the Contractor, and for any further period to which the parties may agree. The order shall be specifically identified as a stop-work order issued under this clause. Upon receipt of the order, the Contractor shall immediately comply with its terms and take all reasonable steps to minimize the incurrence of costs allocable to the work covered by the order during the period of work stoppage. Within a period of 90 days after a stop-work is delivered to the Contractor, or within any extension of that period to which the parties shall have agreed, the Contracting Officer shall either --
(1) Cancel the stop-work order; or
(2) Terminate the work covered by the order as provided in the Termination clause of this contract.
(b) If a stop-work order issued under this clause is canceled or the period of the order or any extension thereof expires, the Contractor shall resume work. The Contracting Officer shall make an equitable adjustment in the delivery schedule, the estimated cost, the fee, or a combination thereof, and in any other terms of the contract that may be affected and the contract shall be modified, in writing, accordingly, if --
(1) The stop-work order results in an increase in the time required for, or in the Contractor’s cost properly allocable to, the performance of any part of this contract; and
(2) The Contractor asserts its right to the adjustment within 30 days after the end of the period of work stoppage; provided, that, if the Contracting Officer decides the facts justify the action, the Contracting Officer may receive and act upon the claim submitted at any time before final payment under this contract.
(c) If a stop-work order is not canceled and the work covered by the order is terminated for the convenience of the Government, the Contracting Officer shall allow reasonable costs resulting from the stop-work order in arriving at the termination settlement.
(d) If a stop-work order is not canceled and the work covered by the order is terminated for default, the Contracting Officer shall allow, by equitable adjustment or otherwise, reasonable costs resulting from the stop-work order.

Section G - Contract Administration Data

G.1  DOE-G-2001 Contracting Officer Authority (Oct 2014) 
The Contracting Officer is responsible for administration of the contract.  The Contracting Officer may appoint a Contracting Officer’s Representative (COR), in accordance with the clause entitled Contracting Officer’s Representative, to perform specifically delegated functions.  The Contracting Officer is the only individual who has the authority on behalf of the Government, among other things, to take the following actions under the contract:
(a)    Assign additional work within the general scope of the contract.
(b)    Issue a change in accordance with the clause entitled Changes.
(c)    Change the cost or price of the contract.
(d)    Change any of the terms, conditions, specifications, or services required by the contract.
(e)    Accept non-conforming work.
(f)    Waive any requirement of the contract.

G.2  DOE-G-2002 Contracting Officer’s Representative (Oct 2014)
Pursuant to the clause at DEAR 952.242-70 entitled Technical Direction, the Contracting Officer shall designate in writing a COR for this contract, and provide a copy of such designation to the Contractor, including the delegated responsibilities and functions.  The COR does not have authority to perform those functions reserved exclusively for the Contracting Officer.

G.3  DOE-G-2003 Contractor’s Program Manager (Oct 2014)
(a)    The Contractor shall designate a Program Manager who will be the Contractor’s authorized supervisor for technical and administrative performance of all work hereunder.  The Program Manager shall be the primary point of contact between the Contractor and the COR under this contract.

(b)    The Program Manager shall receive and execute, on behalf of the Contractor, such technical directions as the COR may issue within the terms and conditions of the contract.

G.4  DOE-G-2004 Contract Administration (Oct 2014)
To promote timely and effective contract administration, correspondence delivered to the Government under this contract shall reference the contract number, title, and subject matter and shall be subject to the following procedures:
(a)    Technical correspondence.  Technical correspondence shall be addressed to the COR for this contract, and a copy of any such correspondence shall be sent to the U.S. Department of Energy (DOE) Contracting Officer.  As used herein, technical correspondence does not include correspondence where patent or rights in data issues are involved, nor technical correspondence that proposes or involves waivers, deviations, or modifications to the requirements, terms, or conditions of this contract.

(b)    Other Correspondence.
(1)    Correspondence regarding patent or rights in data issues should be sent to the Intellectual Property Counsel.  A copy of such correspondence shall also be provided to the Contracting Officer.

(2)    If no Government Contract Administration Office is designated on Standard Form 33 (Block 24), all correspondence, other than technical correspondence and correspondence regarding patent of rights in data, including correspondence regarding waivers, deviations, or modifications to requirements, terms, or conditions of the contract, shall be addressed to the Contracting Officer.  Copies of all such correspondence shall also be provided to the COR.

(3)    Where a Government Contract Administration Office, other than DOE, is designated on either Standard Form 33 (Block 24) or Standard Form 26 (Block 6) of this contract, all correspondence, other than technical correspondence, shall be addressed to the Government Contract Administration Office so designated, with copies of the correspondence to the Contracting Officer and the COR.

(c)    Information regarding correspondence addresses and contact information will be provided through official correspondence:

Contracting Officer
U.S. Department of Energy
Attn: Karen Shears
Telephone number: 865-241-6411
Address: 
200 Administration Road
Oak Ridge, TN 37830
Email address: Karen.Shears@orem.doe.gov

Contracting Officer’s Representative
U.S. Department of Energy
Nuclear Energy – Oak Ridge Site Office
		
	 
	Attn: [To Be Inserted at Time of Award]

Telephone number: [To Be Inserted at Time of Award]
Address: 
200 Administration Road
Oak Ridge, TN 37830
Email address: [To Be Inserted at Time of Award]
Intellectual Property Counsel
Integrated Service Center (ISC) Oak Ridge Office acting through the Intellectual Property Law Division of the Office of Chief Counsel
Telephone number: (865) 576-1077
Address:  
Department of Energy 
P.O. Box 2001 
Oak Ridge, TN 37831-2001
Email address: [To Be Inserted at Time of Award]

G.5  DOE-G-2005 Billing Instructions – Alternate I (Oct 2014) (Revised)
(a)    Contractors shall use Standard Form 1034, Public Voucher for Purchases and Services Other than Personal, when requesting payment for work performed under the contract.  Vouchers for payment shall be submitted timely in accordance with FAR 52.216-7(a)(1).  All invoices shall be supported by a billing schedule summarized by funding source.

(b)    Contractors shall submit vouchers electronically through the Oak Ridge Financial Service Center’s Vendor Inquiry Payment Electronic Reporting System (VIPERS).  VIPERS allows vendors to submit vouchers, attach supporting documentation, and check the payment status of any voucher submitted to the DOE.  Instructions concerning contractor enrollment and use of VIPERS can be found at https://vipers.doe.gov.

(c)    A paper copy of a voucher that has been submitted electronically will not be accepted.

(d)    The voucher must include a statement of cost and supporting documentation for services rendered.  This statement should include, as a minimum, a breakout by cost or price element of all services actually provided by the Contractor, both for the current billing period and cumulatively for the entire contract at the CLIN level (WBS level 2). 

(1)    Statement of Cost.  The Contractor shall prepare and submit a Statement of Cost with each voucher in accordance with the following:
		
	(i)
	Statement of Cost must be completed and consistent with data in the Contractor’s cost accounting system. 

		
	(ii)
	Costs claimed must be only those recorded costs authorized for billing by the payment provisions of the contract. 

		
	(iii)
	Indirect costs claimed must reflect the rates approved for billing purposes by the Contracting Officer. 

		
	(iv)
	The Direct Productive Labor Hours (DPLH) incurred during the current billing period must be shown, and the DPLH summary completed, if applicable. 

		
	(v)
	Costs claimed must be summarized and broken out by cost element (e.g., Labor, Subcontracts, Other Direct Costs, etc.).

		
	(vi)
	Statement of Cost must show total amounts by current billing period, fiscal year to date, and cumulative contract-to-date to facilitate reconciliation of invoiced costs.

		
	(vii)
	Detailed invoice transactions must be provided in Microsoft Excel® format as a supplemental file including labor hours from the timekeeping system, purchase card transactions, subcontract costs, etc.  The detailed invoice transaction data in Excel® format shall include sufficient data fields and detail as deemed necessary by DOE to enable sorting, analyzing, and testing of invoiced costs.

(2)    The Contractor shall prepare and submit the supporting documentation with each voucher in accordance with the following: 
		
	(i)
	Direct costs (e.g., labor, equipment, travel, supplies, etc.) claimed for reimbursement on the Statement of Cost must be adequately supported.  The level of detail provided must clearly indicate where the funds were expended.  For example, support for labor costs must include the labor category (e.g., program manager, senior engineer, technician, etc.), the hourly rate, the labor cost per category, and any claimed overtime; equipment costs must be supported by a list of the equipment purchased, along with the item's cost; supporting data for travel must include the destination of the trip, number and labor category of travelers, transportation costs, per diem costs, and purpose of the trip; and supplies should be categorized by the nature of the items (e.g., office, lab, computer, etc.) and the dollar amount per category.

		
	(ii)
	Any cost sharing or in-kind contributions incurred by the Contractor and/or third party during the billing period must be included. Cost-sharing or in-kind contributions committed under the contract shall be provided in the same format as paragraph (d) of this clause.  

		
	(iii)
	Indirect rates used for billings must be clearly indicated, as well as their basis of application.  When the cognizant Contracting Officer, Administrative Contracting Officer, or auditor approves a change in the billing rates, include a copy of the approval.

		
	(iv)
	All claimed subcontractor costs must be supported by submitting the same detail as outlined herein.

G.6  DOE-G-2007 Contractor Performance Assessment Reporting (Oct 2014) (Revised)
(a)    The Contracting Officer will document the Contractor’s performance under this contract (including any task orders placed against it, if applicable) by using the Contractor Performance Assessment Reporting System (CPARS).  The CPARS information is handled as “Source Selection Information.” Performance assessments entered into CPARS by the Contracting Officer are transmitted to the Past Performance Information Retrieval System (PPIRS), which is maintained by the Department of Defense.  Information in PPIRS is available to authorized Government personnel seeking past performance information when evaluating proposals for award. 

(b)    Contractor performance will be evaluated at least annually at the contract or task order level, as determined by the Contracting Officer.  Evaluation categories may include any or all of the following at the Government’s discretion: (1) Quality, (2) Schedule, (3) Cost Control, (4) Management, (5) Utilization of Small Business, (6) Regulatory Compliance, and (7) Other Areas.  PPIRS information is available at http://www.ppirs.gov, and CPARS information is available at http://www.cpars.gov.  It is recommended that the Contractor take the overview training that can be found on the CPARS website.  The Contractor shall adhere to the process and associated timeline found in the current version of the User Manual for CPARS and respond to such requests within fourteen (14) calendar days of the request.

(d)    In addition to the performance assessments addressed above, the Government will perform other performance assessments necessary for administration of the contract in accordance with other applicable clauses in this contract.

G.7 DOE-G-2008 Non-Supervision of Contractor Employees (Oct 2014)
The Government shall not exercise any supervision or control over Contractor employees performing services under this contract.  The Contractor’s employees shall be held accountable solely to the Contractor’s management, who in turn is responsible for contract performance to the Government.

Section H - Special Contract Requirements

H.1  DOE-H-2014 Contractor Acceptance of Notices of Violation or Alleged Violations, Fines, and Penalties (Oct 2014)
(a)     The Contractor shall accept, in its own name, notices of violation(s) or alleged violations (NOVs/NOAVs) issued by federal or state regulators to the Contractor resulting from the Contractor's performance of work under this Contract, without regard to liability.  The allowability of the costs associated with fines and penalties shall be subject to other provisions of this contract.

(b)     After providing DOE advance written notice, the Contractor shall conduct negotiations with regulators regarding NOVs/NOAVs and fines and penalties.  However, the Contractor shall not make any commitments or offers to regulators that would bind the Government, including monetary obligations, without first obtaining written approval from the CO.  Failure to obtain advance written approval may result in otherwise allowable costs being declared unallowable and/or the Contractor being liable for any excess costs to the Government associated with or resulting from such offers/commitments.

(c)     The Contractor shall notify DOE promptly when it receives service from the regulators of NOVs/NOAVs and fines and penalties.

H.2  DOE-H-2023 Cost Estimating System Requirements (Oct 2014)    
		
	(a)
	Definitions.

“Acceptable estimating system” means an estimating system that complies with the system criteria in paragraph (d) of this clause, and provides for a system that:
		
	(1)
	Is maintained, reliable, and consistently applied;

		
	(2)
	Produces verifiable, supportable, documented, and timely cost estimates that are an acceptable basis for negotiation of fair and reasonable prices;

		
	(3)
	Is consistent with and integrated with the Contractor’s related management systems; and

		
	(4)
	Is subject to applicable financial control systems.

“Estimating system” means the Contractor’s policies, procedures, and practices for budgeting and planning controls, and generating estimates of costs and other data included in proposals submitted to customers in the expectation of receiving contract awards or contract modifications.  Estimating system includes the Contractor’s:
		
	(1)
	Organizational structure;

		
	(2)
	Established lines of authority, duties, and responsibilities;

		
	(3)
	Internal controls and managerial reviews;

		
	(4)
	Flow of work, coordination, and communication; and

		
	(5)
	Budgeting, planning, estimating methods, techniques, accumulation of historical costs, and other analyses used to generate cost estimates.

“Significant deficiency” means a shortcoming in the system that materially affects the ability of officials of the DOE to rely upon information produced by the system that is needed for management purposes.
		
	(b)
	General.  The Contractor shall establish, maintain, and comply with an acceptable estimating system.

		
	(c)
	Applicability.  Paragraphs (d) and (e) of this clause apply if the Contractor is a large business to include a Contractor teaming arrangement, as defined at 48 CFR 9.601(1), performing a Contract in support of a Capital Asset Project (other than a management and operating contract as described at 48 CFR 917.6), as prescribed in DOE Order (DOE O) 413.3B or current version; or a non‐capital asset project and either:

		
	(1)
	The total prime contract value exceeds $50 million, including options; or

		
	(2)
	The Contractor was notified, in writing, by the CO that paragraphs (d) and (e) of this clause apply.

		
	(d)
	System requirements.

		
	(1)
	The Contractor shall disclose its estimating system to the CO, in writing.  If the Contractor wishes the Government to protect the information as privileged or confidential, the Contractor must mark the documents with the appropriate legends before submission.  If the Contractor plans to adopt the existing system from the previous contractor, the Contractor is responsible for the system and shall comply with the system requirements required in this clause.

		
	(2)
	An estimating system disclosure is acceptable when the Contractor has provided the CO with documentation no later than 60 days after contract award that:

		
	(i)
	Accurately describes those policies, procedures, and practices that the Contractor currently uses in preparing cost proposals; and

		
	(ii)
	Provides sufficient detail for the Government to reasonably make an informed judgment regarding the acceptability of the Contractor's estimating practices.

		
	(3)
	The Contractor shall:

		
	(i)
	Comply with its disclosed estimating system; and

		
	(ii)
	Disclose significant changes to the cost estimating system to the CO on a timely basis.

		
	(4)
	The Contractor's estimating system shall provide for the use of appropriate source data, utilize sound estimating techniques and good judgment, maintain a consistent approach, and adhere to established policies and procedures.  An acceptable estimating system shall accomplish the following functions:

		
	(i)
	Establish clear responsibility for preparation, review, and approval of cost estimates and budgets.

		
	(ii)
	Provide a written description of the organization and duties of the personnel responsible for preparing, reviewing, and approving cost estimates and budgets.

		
	(iii)
	Ensure that relevant personnel have sufficient training, experience, and guidance to perform estimating and budgeting tasks in accordance with the Contractor’s established procedures.

		
	(iv)
	Identify and document the sources of data and the estimating methods and rationale used in developing cost estimates and budgets.

		
	(v)
	Provide for adequate supervision throughout the estimating and budgeting process.

		
	(vi)
	Provide for consistent application of estimating and budgeting techniques.

		
	(vii)
	Provide for detection and timely correction of errors.

		
	(viii)
	Protect against cost duplication and omissions.

		
	(ix)
	Provide for the use of historical experience, including historical vendor pricing information, where appropriate.

		
	(x)
	Require use of appropriate analytical methods.

		
	(xi)
	Integrate information available from other management systems.

		
	(xii)
	Require management review, including verification of compliance with the company’s estimating and budgeting policies, procedures, and practices.

		
	(xiii)
	Provide for internal review of, and accountability for, the acceptability of the estimating system, including the budgetary data supporting indirect cost estimates and comparisons of projected results to actual results, and an analysis of any differences.

		
	(xiv)
	Provide procedures to update cost estimates and notify the CO in a timely manner.

		
	(xv)
	Provide procedures that ensure subcontract prices are reasonable based on a documented review and analysis provided with the prime proposal, when practicable.

		
	(xvi)
	Provide estimating and budgeting practices that consistently generate sound proposals that are compliant with the provisions of the solicitation and are adequate to serve as a basis to reach a fair and reasonable price.

		
	(xvii)
	Have an adequate system description, including policies, procedures, and estimating and budgeting practices, that comply with the Federal Acquisition Regulation (48 CFR chapter 1) and DEAR (48 CFR chapter 9).

		
	(e)
	Significant deficiencies.

(1)    The CO will provide an initial determination to the Contractor, in writing, of any significant deficiencies.  The initial determination will describe the deficiency in sufficient detail to allow the Contractor to understand the deficiency.
(2)    The Contractor shall respond within 30 days to a written initial determination from the CO that identifies significant deficiencies in the Contractor’s estimating system.  If the Contractor disagrees with the initial determination, the Contractor shall state, in writing, its rationale for disagreeing.  In the event the Contractor did not respond in writing to the initial determination within the response time, this lack of response shall indicate that the Contractor agrees with the initial determination.
(3)    The CO will evaluate the Contractor’s response or the Contractor’s lack of response and notify the Contractor, in writing, of the CO’s final determination concerning:
		
	(i)
	Remaining significant deficiencies;

		
	(ii)
	The adequacy of any proposed or completed corrective action; and

		
	(iii)
	System disapproval, if the CO determines that one or more significant deficiencies remain.

		
	(f)
	If the Contractor receives the CO’s final determination of significant deficiencies, the Contractor shall, within 45 days of receipt of the final determination, either correct the significant deficiencies or submit an acceptable corrective action plan showing milestones and actions to eliminate the significant deficiencies.

		
	(g)
	Withholding payments.  If the CO makes a final determination to disapprove the Contractor’s estimating system, and the contract includes the Section H clause entitled Contractor Business Systems, the CO will withhold payments in accordance with that clause.

H.3  DOE-H-2025 ACCOUNTING SYSTEM ADMINISTRATION (OCT 2014) (Revised)
(a) Definitions. As used in this clause—-
(1) Acceptable accounting system means a system that complies with the system criteria in paragraph (c) of this clause to provide reasonable assurance that-—
(i) Applicable laws and regulations are complied with;
(ii) The accounting system and cost data are reliable;
(iii) Risk of misallocations and mischarges are minimized; and
(iv) Contract allocations and charges are consistent with billing procedures.
(2) Accounting system means the Contractor's system or systems for accounting methods, procedures, and controls established to gather, record, classify, analyze, summarize, interpret, and present accurate and timely financial data for reporting in compliance with applicable laws, regulations, and management decisions, and may include subsystems for specific areas such as indirect and other direct costs, compensation, billing, labor, and general information technology.
(3) Significant deficiency means a shortcoming in the system that materially affects the ability of officials of the Department of Energy to rely upon information produced by the system that is needed for management purposes.
(b) General. The Contractor shall establish and maintain an acceptable accounting system. The Contractor shall provide in writing to the Contracting Officer documentation that its accounting system meets the system criteria in paragraph (c) of this clause no later than 60 days after contract award. Failure to maintain an acceptable accounting system, as defined in this clause, shall result in the withholding of payments if the contract includes the Section H clause Contractor Business Systems, and also may result in disapproval of the system.
(c) System criteria. The Contractor's accounting system shall provide for—-
(1) A sound internal control environment, accounting framework, and organizational structure;
(2) Proper segregation of direct costs from indirect costs;
(3) Identification and accumulation of direct costs by contract;
(4) A logical and consistent method for the accumulation and allocation of indirect costs to intermediate and final cost objectives;
(5) Accumulation of costs under general ledger control;
(6) Reconciliation of subsidiary cost ledgers and cost objectives to general ledger;
(7) Approval and documentation of adjusting entries;
(8) Management reviews or internal audits of the system to ensure compliance with the Contractor's established policies, procedures, and accounting practices;
(9) A timekeeping system that identifies employees' labor by intermediate or final cost objectives;
(10) A labor distribution system that charges direct and indirect labor to the appropriate cost objectives;
(11) Interim (at least monthly) determination of costs charged to a contract through routine posting of books of account;
(12) Exclusion from costs charged to Government contracts of amounts which are not allowable in terms of 48 CFR part 31, Contract Cost Principles and Procedures, and other contract provisions;
(13) Identification of costs by contract line item and by units (as if each unit or line item were a separate contract), if required by the contract;
(14) Segregation of preproduction costs from production costs, as applicable;
(15) Cost accounting information, as required—-
(i) By contract clauses concerning limitation of cost (48 CFR 52.232-20), limitation of funds (48 CFR 52.232-22), or allowable cost and payment (48 CFR 52.216-7); and
(ii) To readily calculate indirect cost rates from the books of accounts;
(16) Billings that can be reconciled to the cost accounts for both current and cumulative amounts claimed and comply with contract terms;
(17) Adequate, reliable data for use in pricing follow-on acquisitions; and
(18) Accounting practices in accordance with standards promulgated by the Cost Accounting Standards Board, if applicable, otherwise, Generally Accepted Accounting Principles.
(d) Significant deficiencies. (1) The Contracting Officer will provide an initial determination to the Contractor, in writing, on any significant deficiencies. The initial determination will describe the deficiency in sufficient detail to allow the Contractor to understand the deficiency.
(2) The Contractor shall respond within 30 days to a written initial determination from the Contracting Officer that identifies significant deficiencies in the Contractor's accounting system. If the Contractor disagrees with the initial determination, the Contractor shall state, in writing, its rationale for disagreeing. In the event the Contractor did not respond in writing to the initial determination within the response time, this lack of response shall indicate that the Contractor agrees with the initial determination.
(3) The Contracting Officer will evaluate the Contractor's response or the Contractor's lack of response and notify the Contractor, in writing, of the Contracting Officer's final determination concerning—-
(i) Remaining significant deficiencies;
(ii) The adequacy of any proposed or completed corrective action; and
(iii) System disapproval, if the Contracting Officer determines that one or more significant deficiencies remain.
(e) If the Contractor receives the Contracting Officer's final determination of significant deficiencies, the Contractor shall, within 45 days of receipt of the final determination, either correct the significant deficiencies or submit an acceptable corrective action plan showing milestones and actions to eliminate the significant deficiencies.
(f) Withholding payments. If the Contracting Officer makes a final determination to disapprove the Contractor's accounting system, and the contract includes the Section H clause Contractor Business Systems, the Contracting Officer will withhold payments in accordance with that clause.

H.4  DOE-H-2027 CONTRACTOR PROPERTY MANAGEMENT SYSTEM ADMINISTRATION (OCT 2014) (Revised) 
(a) Definitions. As used in this clause—-
Acceptable property management system means a property system that complies with the system criteria in paragraph (c) of this clause.
Property management system means the Contractor's system or systems for managing and controlling Government property.
Significant deficiency means a shortcoming in the system that materially affects the ability of officials of the Department of Energy to rely upon information produced by the system that is needed for management purposes.
(b) General. The Contractor shall establish and maintain an acceptable property management system. The Contractor shall provide in writing to the Contracting Officer documentation that its property management system meets the system criteria in paragraph (c) of this clause no later than 60 days after contract award. Failure to maintain an acceptable property management system, as defined in this clause, may result in disapproval of the system by the Contracting Officer and/or withholding of payments.
(c) System criteria. The Contractor's property management system shall be in accordance with paragraph (f) of the contract clause at 48 CFR 52.245-1.
(d) Significant deficiencies. (1) The Contracting Officer will provide an initial determination to the Contractor, in writing, of any significant deficiencies. The initial determination will describe the deficiency in sufficient detail to allow the Contractor to understand the deficiency.
(2) The Contractor shall respond within 30 days to a written initial determination from the Contracting Officer that identifies significant deficiencies in the Contractor's property management system. If the Contractor disagrees with the initial determination, the Contractor shall state, in writing, its rationale for disagreeing. In the event the Contractor did not respond in writing to the initial determination within the response time, this lack of response shall indicate that the Contractor agrees with the initial determination.
(3) The Contracting Officer will evaluate the Contractor's response or the Contractor's lack of response and notify the Contractor, in writing, of the Contracting Officer's final determination concerning—-
(i) Remaining significant deficiencies;
(ii) The adequacy of any proposed or completed corrective action; and
(iii) System disapproval, if the Contracting Officer determines that one or more significant deficiencies remain.
(e) If the Contractor receives the Contracting Officer's final determination of significant deficiencies, the Contractor shall, within 45 days of receipt of the final determination, either correct the significant deficiencies or submit an acceptable corrective action plan showing milestones and actions to eliminate the significant deficiencies.
(f) Withholding payments. If the Contracting Officer makes a final determination to disapprove the Contractor's property management system, and the contract includes the Section H clause Contractor Business Systems, the Contracting Officer will withhold payments in accordance with that clause.

H.5  DOE-H-2033 ALTERNATIVE DISPUTE RESOLUTION (OCT 2014)
(a) The DOE and the Contractor both recognize that methods for fair and efficient resolution of contractual issues in controversy by mutual agreement are essential to the successful and timely completion of contract requirements. Accordingly, DOE and the Contractor shall use their best efforts to informally resolve any contractual issue in controversy by mutual agreement. Issues of controversy may include a dispute, claim, question, or other disagreement. The parties agree to negotiate with each other in good faith, recognizing their mutual interests, and attempt to reach a just and equitable solution satisfactory to both parties. 
(b) If a mutual agreement cannot be reached through negotiations within a reasonable period of time, the parties may use a process of alternate dispute resolution (ADR) in accordance with the clause at FAR 52.233-1, Disputes. The ADR process may involve mediation, facilitation, fact-finding, group conflict management, and conflict coaching by a neutral party. The neutral party may be an individual, a board comprised of independent experts, or a company with specific expertise in conflict resolution or expertise in the specific area of controversy. The neutral party will not render a binding decision, but will assist the parties in reaching a mutually satisfactory agreement. Any opinions of the neutral party shall not be admissible in evidence in any subsequent litigation proceedings. 
(c) Either party may request that the ADR process be used. The Contractor shall make a written request to the Contracting Officer, and the Contracting Officer shall make a written request to the appropriate official of the Contractor. A voluntary election by both parties is required to participate in the ADR process. The parties must agree on the procedures and terms of the process, and officials of both parties who have the authority to resolve the issue must participate in the agreed upon process. 
(d) ADR procedures may be used at any time that the Contracting Officer has the authority to resolve the issue in controversy. If a claim has been submitted by the Contractor, ADR procedures may be applied to all or a portion of the claim. If ADR procedures are used subsequent to issuance of a Contracting Officer’s final decision under the clause at FAR 52.233-1, Disputes, their use does not alter any of the time limitations or procedural requirements for filing an appeal of the Contracting Officer’s final decision and does not constitute reconsideration of the final decision. 
(e) If the Contracting Officer rejects the Contractor’s request for ADR proceedings, the Contracting Officer shall provide the Contractor with a written explanation of the specific reasons the ADR process is not appropriate for the resolution of the dispute. If the Contractor rejects the Contracting Officer’s request to use ADR procedures, the Contractor shall provide the Contracting Officer with the reasons for rejecting the request.

H.6  DOE-H-2038 NUCLEAR FACILITIES OPERATIONS (OCT 2014)
(a) The work under this contract includes the operation of nuclear facilities. The Contractor recognizes that such operations involve the risk of a nuclear incident which, while the chances are remote, could adversely affect the public’s health and safety and the environment. Therefore, the Contractor shall exercise a degree of care commensurate with the risks involved.
(b) As used in this clause, the term "nuclear materials" is a collective term which includes source material, special nuclear material, and those other materials to which, by direction of DOE, the provisions of DOE's Orders or Directives regarding the control of nuclear materials, which have been or may be furnished to the Contractor by DOE, apply. The Contractor shall accept existing procedures and, in a manner satisfactory to the Contracting Officer, propose revised, as appropriate, accounting and measurement procedures, maintain current records and institute appropriate control measures for nuclear materials in its possession commensurate with the national security and DOE policy. The Contractor shall make such reports and permits subject to inspection as DOE may require with reference to nuclear materials. The Contractor shall take all reasonable steps and precautions to protect such materials against theft and misappropriations and to minimize all losses of such materials. 
(c) Transfers of nuclear materials shall only be made with the prior written approval of the Contracting Officer, or authorized designee. Nuclear materials in the Contractor's possession, custody, or control shall be used only for furtherance of the work under this contract. The Contractor shall be responsible for the control of such nuclear materials in accordance with applicable DOE Orders and Directives regarding the control of nuclear materials, which have been or may be issued to the Contractor by DOE. The Contractor shall make a part of each purchase order, subcontract, and other commitment under this contract involving the use of nuclear materials for which the Contractor has accountability, appropriate terms and conditions for the use of nuclear materials and the responsibilities of the subcontractor or vendor regarding control of nuclear materials. In the case of fixed-price purchase orders, subcontracts, or other commitments involving the use of nuclear materials for which the Contractor has accountability, the terms and conditions with respect to nuclear materials shall also identify who has the financial responsibilities, if any, regarding such items as losses, scrap recovery, product recovery, and disposal.

H.7  DOE-H-2041 SUSTAINABLE ACQUISITION UNDER DOE SERVICE CONTRACTS (OCT 2014) (Revised) 
(a) The Department of Energy (DOE) is committed to managing its facilities in a manner that will promote the natural environment and protect the health and well-being of its Federal employees and contractor service providers. The Contractor shall use its best efforts to support DOE in meeting those commitments, including sustainable acquisition or environmentally preferable contracting which may involve several interacting initiatives, such as - 
(1) Alternative Fueled Vehicles and Alternative Fuels;
(2) Biobased Content Products (USDA Designated Products);
(3) Energy Efficient Products;
(4) Non-Ozone Depleting Alternative Products;
(5) Recycled Content Products (EPA Designated Products); and
(6) Water Efficient Products (EPA WaterSense Labeled Products).
(b) The Contractor should become familiar with these information resources:
(1) Recycled Products are described at http://epa.gov/cpg.
(2) Biobased Products are described at http://www.biopreferred.gov/.
(3) Energy efficient products are described at http://energystar.gov/products for Energy Star products.
(4) FEMP designated products are described at http://www.eere.energy.gov/femp/procurement
(5) Environmentally Preferable Computers are described at http://www.epeat.net.
(6) Non-Ozone Depleting Alternative Products are described at http://www.epa.gov/ozone/strathome.html. 
(7) Water efficient plumbing fixtures are described at http://epa.gov/watersense.
(c) If, in the course of providing services at the DOE site, the Contractor’s services necessitate the acquisition of any of the above types of products, it is expected that the Contractor will acquire the sustainable, environmentally preferable models unless the product is not available competitively within a reasonable time, at a reasonable price, is not life cycle cost efficient in the case of energy consuming products, or does not meet reasonable performance standards. While there is no formal reporting, DOE prepares a sustainable acquisition annual report and the Contractor may be asked by the Contracting Officer to provide information in support of DOE’s report.

H.8  DOE-H-2044 MATERIAL SAFETY DATA SHEET AVAILABILITY (OCT 2014)
In implementation of the clause at FAR 52.223-3, Hazardous Material Identification and Material Safety Data, the Contractor shall obtain, review and maintain a Material Safety Data Sheet (MSDS) in a readily accessible manner for each hazardous material (or mixture containing a hazardous material) ordered, delivered, stored or used; and maintain an accurate inventory and history of use of hazardous materials at each use and storage location. The MSDS shall conform to the requirements of 29 CFR 1910.1200(g).

H.9  DOE-H-2046 DIVERSITY PROGRAM (OCT 2014)
(a) The Contractor shall develop and implement a diversity program consistent with and in support of the DOE’s diversity program. A diversity plan covering the full period of performance (base and option periods) shall be submitted to the Contracting Officer for approval within 30 calendar days after the effective date of the contract. Once the diversity plan is approved by the Contracting Officer, the Contractor shall implement the diversity plan within 15 calendar days of its approval by the Contracting Officer.
(b) The diversity plan shall address, at a minimum, the Contractor's approach to ensure an effective diversity program (including addressing applicable affirmative action and equal employment opportunity regulations) to include: (1) a statement of the Contractor's policies and practices; and (2) planned initiatives and activities which demonstrate a commitment to a diversity program, including recruitment strategies for hiring a diverse work force. The diversity plan shall also address, as a minimum, the Contractor's approach for promoting diversity through (1) the Contractor's work force; (2) educational outreach, including a mentor-protégé program; (3) stakeholder involvement and outreach; (4) subcontracting; and (5) economic development.
(c) An annual diversity report shall be submitted pursuant to Section J. This report shall provide a list of accomplishments achieved, both internally and externally during the current reporting period, and projected initiatives during the next reporting period. The report shall also list any proposed changes to the diversity plan which shall be subject to the Contracting Officer’s approval.

H.10  DOE-H-2048 PUBLIC AFFAIRS – CONTRACTOR RELEASES OF INFORMATION (OCT 2014)
In implementation of the clause at DEAR 952.204-75, Public Affairs, all communications or releases of information to the public, the media, or Members of Congress prepared by the Contractor related to work performed under the contract shall be reviewed and approved by DOE prior to issuance. Therefore, the Contractor shall, at least 5 calendar days prior to the planned issue date, submit a draft copy to the Contracting Officer of any planned communications or releases of information to the public, the media, or Members of Congress related to work performed under this contract. The Contracting Officer will obtain necessary reviews and clearances and provide the Contractor with the results of such reviews prior to the planned issue date.  The Contractor, as a publicly traded company, must comply with SEC reporting and disclosure requirements.  Nothing in this Clause shall be construed as (i) preventing the Contractor from meeting its SEC reporting and disclosure requirements or (ii) requiring the Contractor  to violate its SEC reporting and disclosure requirements..   

H.11  DOE-H-2049 INSURANCE REQUIREMENTS (OCT 2014)
(a) In accordance with the clause FAR 52.228-5, the following types and minimum amounts of insurance shall be maintained by the Contractor:
(1) Workers’ compensation – Amount in accordance with applicable Federal and State workers’ compensation and occupational disease statutes.
(2) Employer’s liability - $100,000 (except in States with exclusive or monopolistic funds that do not permit worker’s compensation to be written by private carriers).
(3) Comprehensive bodily injury liability - $500,000.
(4) Property damage liability – None, unless otherwise required by the Contracting Officer.
(5) Comprehensive automobile bodily injury liability - $200,000 per person and $500,000 per occurrence.
(6) Comprehensive automobile property damage - $20,000 per occurrence.
(b) The Contractor shall provide evidence of such insurance, if requested by the Contracting Officer; and the Contracting Officer may require such evidence to be provided prior to the commencement of work under the contract.

H.12  DOE-H-2052 REPRESENTATIONS, CERTIFICATIONS, AND OTHER STATEMENTS OF THE OFFEROR
The following additional contractor Representations, Certifications and Other Statements are hereby incorporated into the contract by reference:
Name of the Representations, Certifications and Other Statements
[]
Date
[]

H.13 DOE-H-2056 ANNUAL INDIRECT BILLING RATES (OCT 2014)
(a) Pursuant to the clause at FAR 52.216-7, Allowable Cost and Payment, indirect billing rates, revised billing rates (as necessary), and final indirect cost rate agreements must be established between the Contractor and the Department of Energy (DOE) for each of the Contractor's fiscal years for the life of the cost reimbursement type contract. These indirect rate agreements allow the Contractor to recover indirect expenses incurred during a fiscal year for which final indirect rates have not been established. 
(b) Indirect billing and revised indirect billing rate proposals must represent the Contractor's best estimate of the anticipated indirect expenses to be incurred and the estimated allocation base for the current fiscal year in accordance with its approved accounting system. Revised billing rates allow the adjustment of the approved billing rates, based upon updated information, in order to prevent significant over or under billings. 
(c) The establishment of rates for the reimbursement of independent research and development/bid and proposal costs shall be in accordance with the provisions of FAR Subpart 42.7, “Indirect Cost Rates,” FAR 31.205-18, "Independent Research and Development and Bid and Proposal Costs," and DEAR 931.205-18, "Independent Research and Development (IR&D) and Bid and Proposal (B&P) Costs." 
(d) Paragraph (e) below, identifies the requirements and process to be followed by the Contractor in establishing indirect rates for contracts when DOE is the Cognizant Federal Agency (CFA) and when DOE is not the CFA. Specific instructions for submittal of indirect rate proposals to agencies other than DOE must be obtained from the agency involved. 
(e) Requirements whether or not DOE is the CFA. (1) Allowability of costs and acceptability of cost allocation methods shall be determined in accordance with the applicable sections of FAR Part 30, Cost Accounting Standards, FAR Part 31 and DEAR 931, Contract Cost Principles and Procedures, in effect as of the date of this contract. 
(2) Pending settlement of the final indirect expense rates for any period, the Contractor shall be reimbursed at billing rates approved by the CFA subject to acknowledgment by the cognizant DOE Contracting Officer. These billing rates are subject to appropriate adjustments when revised by mutual agreement or when the final indirect rates are settled, either by mutual agreement or unilateral determination by the CFA subject to acknowledgment by the cognizant DOE Contracting Officer. 
(3) The Contractor shall continue to use the latest DOE or CFA approved billing rate(s) which have been acknowledged by the cognizant DOE Contracting Officer until those rates are superseded by establishment of final rates or more current billing rates. In those cases where current billing rates have not been established, the latest approved final rates shall be used for invoicing, unless it is determined by the cognizant DOE Contracting Officer that use of said rates would not provide for an equitable recovery of indirect costs. In those instances, the cognizant DOE Contracting Officer will take whatever steps are necessary to establish rates that DOE considers to be reasonable for billing purposes.

H.14  DOE-H-2057 DEPARTMENT OF LABOR WAGE DETERMINATIONS (OCT 2014)
The Contractor’s performance under this contract shall comply with the requirements of the U.S. Department of Labor Wage Determination(s) located in Section J, Attachment 3 and the clause at FAR 52.222-42, Statement of Equivalent Rates for Federal Hires.

H.15  DOE-H-2059 PRESERVATION OF ANTIQUITIES, WILDLIFE AND LAND AREAS (OCT 2014)
(a) Federal Law provides for the protection of antiquities located on land owned or controlled by the Government. Antiquities include Indian graves or campsites, relics and artifacts. The Contractor shall control the movements of its personnel and its subcontractor's personnel at the job site to ensure that any existing antiquities discovered thereon will not be disturbed or destroyed by such personnel. It shall be the duty of the Contractor to report to the Contracting Officer the existence of any antiquities so discovered. 
(b) The Contractor shall also preserve all vegetation (including wetlands) except where such vegetation must be removed for survey or construction purposes. Any removal of vegetation shall be in accordance with the terms of applicable habitat mitigation plans and permits. Furthermore, all wildlife must be protected consistent with programs approved by the Contacting Officer.
(c) Except as required by or specifically provided for in other provisions of this contract, the Contractor shall not perform any excavations, earth borrow, preparation of borrow areas, or otherwise disturb the surface soils within the job site without the prior approval of DOE or its designee.

H.16  DOE-H-2061 CHANGE ORDER ACCOUNTING (OCT 2014)
The Contractor shall maintain change order accounting whenever the estimated cost of a change or series of related changes exceeds $100,000. The Contractor, for each change or series of related changes, shall maintain separate accounts, by job order or other suitable accounting procedure, of all incurred segregable, direct costs (less allocable credits) of work, both changed and not changed, allocable to the change. The Contractor shall maintain such accounts until the parties agree to an equitable adjustment for the changes ordered by the Contracting Officer or the matter is conclusively disposed of in accordance with the Disputes clause.

H.17  DOE-H-2062 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR PERSONNEL (OCT 2014)
(a) Pursuant to the clause at FAR 52.204-9, Personal Identity Verification of Contractor Personnel, the Contractor shall comply with applicable DOE regulations, policies and directives regarding identification, credential and access management for its personnel who have routine physical access to DOE-owned or -controlled sites or facilities or routine access to DOE information systems. 
(b) The Contractor shall comply with the requirements of those DOE directives, or parts thereof, identified below in implementing the requirements of this clause. The Contracting Officer may, at any time, unilaterally amend this clause in order to add, modify or delete specific requirements.

H.18  DOE-H-2065 REPORTING OF FRAUD, WASTE, ABUSE, CORRUPTION, OR MISMANAGEMENT (OCT 2014)
The Contractor shall comply with the following:
(a) Notify employees annually of their duty to report allegations of fraud, waste, abuse, misuse, corruption, criminal acts, or mismanagement relating to DOE programs, operations, facilities, contracts, or information technology systems to an appropriate authority (e.g., OIG, other law enforcement, supervisor, employee concerns office, security officials). Examples of violations to be reported include, but are not limited to, allegations of false statements; false claims; bribery; kickbacks; fraud; DOE environment, safety, and health violations; theft; computer crimes; contractor mischarging; conflicts of interest; and conspiracy to commit any of these acts. Contractors must also ensure that their employees are aware that they may always report incidents or information directly to the Office of Inspector General (OIG).
(b) Display the OIG hotline telephone number in buildings and common areas such as cafeterias, public telephone areas, official bulletin boards, reception rooms, and building lobbies.
(c) Publish the OIG hotline telephone number in telephone books and newsletters under the Contractor’s cognizance.
(d) Ensure that its employees report to the OIG within a reasonable period of time, but not later than 24 hours after discovery, all alleged violations of law, regulations, or policy, including incidents of fraud, waste, abuse, misuse, corruption, criminal acts, or mismanagement, that have been referred to Federal, State, or local law enforcement entities.
(e) Ensure that its employees report to the OIG any allegations of reprisals taken against employees who have reported to the OIG fraud, waste, abuse, misuse, corruption, criminal acts, or mismanagement.
(f) Ensure that its managers do not retaliate against DOE contractor employees who report fraud, waste, abuse, misuse, corruption, criminal acts, or mismanagement.
(g) Ensure that all their employees understand that they must – 
(1) Comply with requests for interviews and briefings and must provide affidavits or sworn statements, if so requested by an employee of the OIG so designated to take affidavits or sworn statements;
(2) Not impede or hinder another employee's cooperation with the OIG; and
(3) Not take reprisals against DOE contractor employees who cooperate with or disclose information to the OIG or other lawful appropriate authority.
(h) Seek more specific guidance concerning reporting of fraud, waste, abuse, corruption, or mismanagement, and cooperation with the Inspector General, in DOE directives.

H.19  DOE-H-2068 CONFERENCE MANAGEMENT (OCT 2014)
The Contractor agrees that:
a) The contractor shall ensure that contractor-sponsored conferences reflect the DOE/NNSA’s commitment to fiscal responsibility, appropriate stewardship of taxpayer funds and support the mission of DOE/NNSA as well as other sponsors of work. In addition, the contractor will ensure conferences do not include any activities that create the appearance of taxpayer funds being used in a questionable manner. 
b) For the purposes of this clause, “conference” is defined in Attachment 2 to the Deputy Secretary’s memorandum of August 17, 2015 entitled “Updated Guidance on Conference-Related Activities and Spending.” 
c) Contractor-sponsored conferences include those events that meet the conference definition and either or both of the following: 
1) The contractor provides funding to plan, promote, or implement an event, except in instances where a contractor:
i) covers participation costs in a conference for specified individuals (e.g. students, retirees, speakers, etc.) in a total amount not to exceed $10,000 (by individual contractor for a specific conference) or
ii) purchases goods or services from the conference planners (e.g., attendee registration fees, renting booth space).
2) The contractor authorizes use of its official seal, or other seals/logos/ trademarks to promote a conference. Exceptions include non-M&O contractors who use their seal to promote a conference that is unrelated to their DOE contract(s) (e.g., if a DOE IT contractor were to host a general conference on cyber security). 
d) Attending a conference, giving a speech or serving as an honorary chairperson does not connote sponsorship.
e) The contactor will provide information on conferences they plan to sponsor with expected costs exceeding $100,000 in the Department’s Conference Management Tool, including: 
1) Conference title, description, and date
2) Location and venue
3) Description of any unusual expenses (e.g., promotional items)
4) Description of contracting procedures used (e.g., competition for space/support)
5) Costs for space, food/beverages, audio visual, travel/per diem, registration costs, recovered costs (e.g., through exhibit fees) 
6) Number of attendees
f) The contractor will not expend funds on the proposed contractor-sponsored conferences with expenditures estimated to exceed $100,000 until notified of approval by the contracting officer.
g) For DOE-sponsored conferences, the contractor will not expend funds on the proposed conference until notified by the contracting officer. 
1) DOE-sponsored conferences include events that meet the definition of a conference and where the Department provides funding to plan, promote, or implement the conference and/or authorizes use of the official DOE seal, or other seals/logos/ trademarks to promote a conference. Exceptions include instances where DOE: 
i) covers participation costs in a conference for specified individuals (e.g. students, retirees, speakers, etc.) in a total amount not to exceed $10,000 (by individual contractor for a specific conference) or
ii) purchases goods or services from the conference planners (e.g., attendee registration fees; renting booth space); or provide funding to the conference planners through Federal grants. 
2) Attending a conference, giving a speech, or serving as an honorary chairperson does not connote sponsorship. 
3) The contractor will provide cost and attendance information on their participation in all DOE-sponsored conference in the DOE Conference Management Tool. 
h) For non-contractor sponsored conferences, the contractor shall develop and implement a process to ensure costs related to conferences are allowable, allocable, reasonable, and further the mission of DOE/NNSA. This process must at a minimum:
1) Track all conference expenses. 
2) Require the Laboratory Director (or equivalent) or Chief Operating Officer approve a single conference with net costs to the contractor of $100,000 or greater.
i) Contractors are not required to enter information on non-sponsored conferences in DOE’S Conference Management Tool. 
Once funds have been expended on a non-sponsored conference, contractors may not authorize the use of their trademarks/logos for the conference, provide the conference planners with more than $10,000 for specified individuals to participate in the conference, or provide any other sponsorship funding for the conference. If a contractor does so, its expenditures for the conference may be deemed unallowable.

H.20  DOE-H-2070 KEY PERSONNEL (OCT 2014) (Revised)
(a) Pursuant to the clause at DEAR 952.215-70, Key Personnel, the key personnel for this contract are identified below:
NAME: [] 
POSITION/TITLE: []
In addition to the requirement for the Contracting Officer’s approval before removing, replacing, or diverting any of the listed key personnel, the Contracting Officer’s approval is also required for any change to the position assignment of a current key person.
(b) Key personnel team requirements. The Contracting Officer and designated Contracting Officer's Representative(s) shall have direct access to the key personnel assigned to the contract. All key personnel shall be permanently assigned to their respective positions. 
(c) Definitions. In addition to the definitions contained in the clause at DEAR 952.215-70, the following shall apply:
(1) The term “reasonably in advance” is defined as 30 calendar days.

H.21  DOE-H-2071 DEPARTMENT OF ENERGY DIRECTIVES (OCT 2014) (Revised)
(a) In performing work under this contract, the Contractor shall comply with the requirements of those Department of Energy (DOE) directives in Section J of the contract.
(b) The Contracting Officer may, at any time, unilaterally amend this clause, or other clauses which incorporate DOE directives, in order to add, modify or delete specific requirements. Prior to revising the listing of directives, the Contracting Officer shall notify the Contractor in writing of the Department's intent to revise the list, and the Contractor shall be provided with the opportunity to assess the effect of the Contractor's compliance with the revised list on contract cost and funding, technical performance, and schedule, and identify any potential inconsistencies between the revised list and the other terms and conditions of the contract. Within 30 days after receipt of the Contracting Officer's notice, the Contractor shall advise the Contracting Officer in writing of the potential impact of the Contractor's compliance with the revised list. Based on the information provided by the Contractor and any other information available, the Contracting Officer shall decide whether to revise the listing of directives and so advise the Contractor not later than 30 days prior to the effective date of the revision.
(c) Notwithstanding the process described in paragraph (b), the Contracting Officer may direct the Contractor to immediately begin compliance with the requirements of any directive.
(d) The Contractor and the Contracting Officer shall identify and, if appropriate, agree to any changes to other contract terms and conditions, including cost and schedule, associated with the revision pursuant to the Changes clauses included in this contract.
(e) Regardless of the performer of the work, the Contractor is responsible for compliance with the requirements of this clause. The Contractor shall include this clause in all subcontracts to the extent necessary to ensure the Contractor’s compliance with these requirements.

H.22  DOE-H-2075 PROHIBITION ON FUNDING FOR CERTAIN NONDISCLOSURE AGREEMENTS (OCT 2014)
The Contractor agrees that:
a) No cost associated with implementation or enforcement of nondisclosure policies, forms or agreements shall be allowable under this contract if such policies, forms or agreements do not contain the following provisions: ‘‘These provisions are consistent with and do not supersede, conflict with, or otherwise alter the employee obligations, rights, or liabilities created by existing statute or Executive order relating to (1) classified information, (2) communications to Congress, (3) the reporting to an Inspector General of a violation of any law, rule, or regulation, or mismanagement, a gross waste of funds, an abuse of authority, or a substantial and specific danger to public health or safety, or (4) any other whistleblower protection. The definitions, requirements, obligations, rights, sanctions, and liabilities created by controlling Executive orders and statutory provisions are incorporated into this agreement and are controlling.’’
b) The limitation above shall not contravene requirements applicable to Standard Form 312, Form 4414, or any other form issued by a Federal department or agency governing the nondisclosure of classified information.
c) Notwithstanding the provisions of paragraph (a), a nondisclosure or confidentiality policy form or agreement that is to be executed by a person connected with the conduct of an intelligence or intelligence-related activity, other than an employee or officer of the United States Government, may contain provisions appropriate to the particular activity for which such document is to be used. Such form or agreement shall, at a minimum, require that the person will not disclose any classified information received in the course of such activity unless specifically authorized to do so by the United States Government. Such nondisclosure or confidentiality forms shall also make it clear that they do not bar disclosures to Congress, or to an authorized official of an executive agency or the Department of Justice, that are essential to reporting a substantial violation of law.

H.23  DOE-H-2076 LOBBYING RESTRICTIONS (NOV 2018)
In accordance with 18 U.S.C. § 1913, the Contractor agrees that none of the funds obligated on this award shall be expended, directly or indirectly, to influence congressional action on any legislation or appropriation matters pending before Congress. This restriction is in addition to those prescribed elsewhere in statute and regulation. 

H.24  DOE-H-2077 DEPARTMENT OF ENERGY TRAINING INSTITUTE – OCCUPATIONAL HEALTH, SAFETY, AND EMERGENCY RESPONSE (JAN 2017)
(a) The Contractor shall utilize the Department of Energy (DOE) Training Institute (DTI) resources to the maximum extent practical for occupational, health, safety, and emergency response training. The Contractor, as applicable, shall use DTI by utilizing the reciprocity program, instructor-certification, mobile training teams, and use of common core curriculum as applicable. 
(1) Reciprocity: The DTI Training Reciprocity program evaluates and certifies training programs and core content against DOE requirements, establishing a basis for consistent training. Reciprocity reduces redundant training to improve employee mobility and project mobilization, saving time and resources. Reference DOE Policy 364.1.
(2) Common Core Curriculum: Courses in the Common Core Training Program are developed and maintained by DTI instructional designers and subject matter experts. These courses are available enterprise-wide for delivery by DTI-certified instructors. Common Core Training eliminates duplicative course development and maintenance activities while providing maximum flexibility for delivery.
(3) Instructor-Certification: The DTI Instructor Certification Program recognizes subject matter experts and experienced trainers who are qualified to deliver common core courses across the DOE enterprise. The Contractor selects instructors to be certified by DTI.
(4) Mobile Training Teams: Mobile Training Teams are available to DOE locations who do not maintain the capability to deliver a specific course. Courses are delivered by certified DTI instructors who are subject matter experts in the topical area.
(b) DTI course offerings, information on becoming a certified DTI trainer, enrollment, and contact information can be found on https://dti.doe.gov.
(c) DTI training shall be considered common core fundamental material. Contractors are expected to provide gap training needed to address site specifics identified through their approved Integrated Safety Management (ISM) Program and associated program plans required by existing DOE requirements. Gap training shall not repeat fundamental training core content.
(d) DTI training is funded by DOE with no cost to the Contractors.
(e) The Contractor shall first consider DTI for all applicable training needs and only obtain such training outside of DTI after written approval of the Contracting Officer (CO) following the Contractor's written request containing the following: (1) rationale describing in detail why DTI provided material, including contractor supplemented site specific material, is insufficient, (2) rationale supporting the increased cost, scope, and schedule of maintaining a local course and capability for training instruction proposed in place of DTI training, and (3) rationale as to why the loss of standardization DOE is seeking by using alternative materials is of value to the DOE. Prior to requesting CO approval, the contractor shall complete the course request form at https://dti.doe.gov. DTI will respond within 10 working days on the availability of DTI course materials that might provide the course or assist in the development of the Contractor course.
(f) This contract clause shall be flowed down to all subcontractors, and the Contractor is responsible for compliance by its employees and subcontractors.

H.25  DOE-H-2078 MULTIFACTOR AUTHENTICATION FOR INFORMATION SYSTEMS
The Contractor shall take all necessary actions to achieve multifactor authentication (MFA) for standard and privileged user accounts of all classified and unclassified networks. In so doing, the Contractor shall comply with the requirements and procedures established in the document "U.S. Department of Energy Multifactor Authentication Implementation Approach" and its appendices as determined by the Contracting Officer.

H.26  DOE-H-2079 AGREEMENT REGARDING WORKPLACE SUBSTANCE ABUSE PROGRAMS AT DOE SITES (APR 2018) (Revised)
(a) This contract is subject to the policies, criteria, and procedures of 10 CFR part 707, Workplace Substance Abuse Programs at DOE Sites. 
(b) With the award of the letter contract, the Contractor agrees to provide to the Contracting Officer, within 30 days after notification of selection for award, or award of a contract, whichever occurs first, pursuant to this solicitation, its written workplace substance abuse program consistent with the requirements of 10 CFR part 707. DOE may grant an extension to the notification or implementation period if necessary as per 10 CFR 707.5(g).
(c) Failure of the Contractor to agree to the condition of responsibility set forth in paragraph (b) of this provision, renders the Contractor unqualified and ineligible for award.

H.27  DOE-H-2080 WORKPLACE SUBSTANCE ABUSE PROGRAMS AT DOE SITES (APR 2018)
(a) Program implementation. The Contractor shall, consistent with 10 CFR part 707, Workplace Substance Abuse Programs at DOE Sites, incorporated herein by reference with full force and effect, develop, implement, and maintain a workplace substance abuse program. 
(b) Remedies. In addition to any other remedies available to the Government, the Contractor's failure to comply with the requirements of 10 CFR part 707 or to perform in a manner consistent with its approved program may render the Contractor subject to: the suspension of contract payments, or, where applicable, a reduction in award fee; termination for default; and suspension or debarment. 
(c) Subcontracts. (1) The Contractor agrees to notify the Contracting Officer reasonably in advance of, but not later than 30 days prior to, the award of any subcontract the Contractor believes may be subject to the requirements of 10 CFR part 707, unless the Contracting Officer agrees to a different date.
(2) The DOE Prime Contractor shall require all subcontracts subject to the provisions of 10 CFR part 707 to agree to develop and implement a workplace substance abuse program that complies with the requirements of 10 CFR part 707, Workplace Substance Abuse Programs at DOE Sites, as a condition for award of the subcontract. The DOE Prime Contractor shall review and approve each subcontractor's program, and shall periodically monitor each subcontractor's implementation of the program for effectiveness and compliance with 10 CFR part 707. 
(3) The Contractor agrees to include, and require the inclusion of, the requirements of this clause in all subcontracts, at any tier, that are subject to the provisions of 10 CFR part 707.

H.28  Emergency Response
		
	(a)
	The U.S. Department of Energy (DOE) Nuclear Energy Oak Ridge Site Office Manager, DOE Portsmouth Site Manager, or Contractor shall determine when an emergency situation may exist and notify the appropriate emergency response organization (e.g., Laboratory Shift Superintendent, Plant Shift Superintendent).  In the event of an emergency, the DOE Manager of the affected site will have the authority to direct any and all activities of the Contractor and subcontractors necessary to resolve the emergency situation in accordance with ACO’s NRC License SNM 7003.  Upon termination of the emergency event, the Contractor shall perform recovery actions as appropriate.

		
	(b)
	The Contractor shall include this Clause in all subcontracts at any tier for work performed in support of the on-site work under this contract.

H.29  Security Qualifications
		
	(a)
	The Contractor may be required to perform work in designated security areas or work with documents or information that may require an access authorization (clearance).  Additionally, the scope of the work may require enrollment in the DOE Human Reliability Program (see 10 CFR Part 712, Human Reliability Program.  The Contractor shall ensure that personnel assigned under this Contract and working with classified information, matter, and/or materials possess a DOE “Q” or “L” access authorization (clearance) matching the classification level of the data and information the employee will be required to work on in the performance of their assigned tasks.

		
	(b)
	Individuals that do not require a “Q” or “L” clearance will possess either a Local Site Specific Only badge (temporary only) or HSPD-12 badge.  The Contractor shall not propose non‐U.S. citizens for positions requiring security clearances (Clearance-Access authorizations are granted by the DOE pursuant to 10 CFR Part 710, Criteria and Procedures for Determining Eligibility for Access to Classified Matter or Special Nuclear Material). Security badges must be worn properly while working at DOE facilities.

		
	(c)
	Clearances will be provided and paid for by DOE.  The request for clearance and renewal of clearances must be justified based on actual job performance requirements.  Uncleared personnel requiring access to security areas where security clearances are needed for unescorted access shall be escorted in these areas by approved escorts. 

		
	(d)
	The Contractor shall conduct pre-employment screening of prospective employees in order to ensure trustworthiness and reliability.  Pre-employment screening shall include, as a minimum, verification of personal identity, previous employment, and education, and the results of a credit and law enforcement check.  There is no pre-screening required for incumbent employees that do not have a “Q” or “L” clearance.

		
	(e)
	Requests for access authorization shall not be submitted until the Contract has been awarded, and a favorable Foreign Ownership, Control, or Influence determination must be rendered by DOE before an access authorization will be granted, reinstated, continued, extended, or transferred for employees or prospective employees on the contract.

		
	(f)
	The Contractor shall turn in badges for employees: (1) who are no longer working on the Contract; (2) who no longer require access; (3) when their badge expires; or (4) when the Contract expires or is terminated.

H.30  DOE-H-2019 Disposition of Intellectual Property – Failure to Complete Contract Performance (Oct 2014) (Revised) 

The following provisions shall apply in the event the Contractor does not complete contract performance for any reason:

(a)    Regarding technical data and other intellectual property, DOE may take possession of all technical data, including proprietary data and data obtained from subcontractors, licensors, and licensees, necessary to operate the treatment facility ("facility"), subject to the Rights in Data clause of this contract, as well as the designs, operation manuals, flowcharts, software, etc., construction work in progress, completed manuals, flowcharts, completed facilities, equipment and other property and information necessary for performance of the work or operation of the facility to treat the waste in conformance with the purpose of this contract.  Proprietary data will be protected in accordance with the limited rights data provisions of the Rights in Data Clause.

 (b)    The Contractor agrees to and does hereby grant to the Government an irrevocable non-exclusive, paid-up license in and to any inventions or discoveries regardless of when conceived or actually reduced to practice or acquired by the Contractor, and any other intellectual property, which are owned or controlled by the Contractor, at any time through completion of this contract and which are incorporated or embodied in the construction of the facility or which are utilized in the operation of the facility or which covers articles, materials, or products manufactured at the facility, (1) to practice or to have practiced by or for the Government at the facility, and (2) to transfer such license with the transfer of that facility.  The acceptance or exercise by the Government of the aforesaid rights and license shall not prevent the Government at any time from contesting the enforceability, validity, or scope of, or title to, any rights or patents or other intellectual property herein licensed.

(c)    In addition, the Contractor will take all necessary steps to assign any licenses in any third party intellectual property for operations and closure of the facility to DOE or such other third party as DOE may designate.

H.31  DOE-H-2021 Work Stoppage and Shutdown Authorization (Oct 2014)
		
	(a)
	Imminent Health and Safety Hazard is a given condition or situation which, if not immediately corrected, could result in serious injury or death, including exposure to radiation and toxic/hazardous chemicals.  Imminent Danger in relation to the facility safety envelope is a condition, situation, or proposed activity which, if not terminated, could cause, prevent mitigation of, or seriously increase the risk of (1) nuclear criticality, (2) radiation exposure, (3) fire/explosion, and/or (4) toxic hazardous chemical exposure.

		
	(b)
	Work Stoppage.  In the event of an Imminent Health and Safety Hazard, identified by facility line management or operators or facility health and safety personnel overseeing facility operations, or other individuals, the individual or group identifying the imminent hazard situation shall immediately take actions to eliminate or mitigate the hazard (e.g., directing the operator/implementer of the activity or process causing the imminent hazard to stop work, initiating emergency response actions or other actions) to protect the health and safety of the workers and the public, and to protect DOE facilities and the environment.  In the event an Imminent Health and Safety Hazard is identified, the individual or group identifying the hazard should coordinate with an appropriate Contractor official, who will direct the shutdown or other actions, as required.  Such mitigating action(s) should subsequently be coordinated with the DOE and Contractor management.  The suspension or stop‐work order should be promptly confirmed in writing by the CO.

		
	(c)
	Shutdown.  In the event of an imminent danger in relation to the facility safety envelope or a non‐Imminent Health and Safety Hazard identified by facility line managers, facility operators, health and safety personnel overseeing facility operations, or other individuals, the individual or group identifying the potential health and safety hazard may recommend facility shutdown in addition to any immediate actions needed to mitigate the situation.  However, the recommendation must be coordinated with Contractor management and the DOE Site Manager.  Any written direction to suspend operations shall be issued by the CO, pursuant to FAR 52.242‐15 clause entitled Stop-Work Order.

		
	(d)
	Facility Representatives.  DOE personnel designated as Facility Representatives provide the technical/safety oversight of operations.  The Facility Representative has the authority to “stop work,” which applies to the shutdown of an entire plant, activity, or job.  This stop‐work authority will be used for an operation of a facility which is performing work the Facility Representative believes:

		
	(1)
	Poses an imminent danger to health and safety of workers or the public if allowed to continue;

		
	(2)
	Could adversely affect the safe operation of, or could cause serious damage to, the facility if allowed to continue; or

		
	(3)
	Could result in the release of radiological or chemical hazards to the environment in excess of regulatory limits.

		
	(e)
	This clause flows down to all subcontractors at all tiers.  Therefore, the Contractor shall insert a clause, modified appropriately to substitute “Contractor Representatives” for “the CO,” in all subcontracts.

H.32  NRC NUCLEAR MATERIALS LICENSE

Contractor will construct, maintain, and operate the site under a license granted by the NRC and in accordance with the Memorandum of Understanding between Department of Energy and the Nuclear Regulatory Commission on Cooperation Regarding the American Centrifuge Plant in Piketon, Ohio (DOE-NRC MOU).  Further, in the performance of this Contract, the Contractor will abide by all conditions and requirements included in the NRC Nuclear Materials License (SNM-7003) and regulations for this activity and with the requirements contained in the DOE-NRC MOU.

Section I - Contract Clauses

I.1  52.202-1 -- Definitions (Nov 2013)
When a solicitation provision or contract clause uses a word or term that is defined in the Federal Acquisition Regulation (FAR), the word or term has the same meaning as the definition in FAR 2.101 in effect at the time the solicitation was issued, unless--
(a) The solicitation, or amended solicitation, provides a different definition;
(b) The contracting parties agree to a different definition;
(c) The part, subpart, or section of the FAR where the provision or clause is prescribed provides a different meaning; or
(d) The word or term is defined in FAR Part 31, for use in the cost principles and procedures.

I.2  52.203-3 – Gratuities (Apr 1984)
(a) The right of the Contractor to proceed may be terminated by written notice if, after notice and hearing, the agency head or a designee determines that the Contractor, its agent, or another representative --
(1) Offered or gave a gratuity (e.g., an entertainment or gift) to an officer, official, or employee of the Government; and
(2) Intended, by the gratuity, to obtain a contract or favorable treatment under a contract.
(b) The facts supporting this determination may be reviewed by any court having lawful jurisdiction.
(c) If this contract is terminated under paragraph (a) of this clause, the Government is entitled --
(1) To pursue the same remedies as in a breach of the contract; and
(2) In addition to any other damages provided by law, to exemplary damages of not less than 3 nor more than 10 times the cost incurred by the Contractor in giving gratuities to the person concerned, as determined by the agency head or a designee. (This subparagraph (c)(2) is applicable only if this contract uses money appropriated to the Department of Defense.)
(d) The rights and remedies of the Government provided in this clause shall not be exclusive and are in addition to any other rights and remedies provided by law or under this contract.

I.3  52.203-5 -- Covenant Against Contingent Fees (May 2014)
(a) The Contractor warrants that no person or agency has been employed or retained to solicit or obtain this contract upon an agreement or understanding for a contingent fee, except a bona fide employee or agency. For breach or violation of this warranty, the Government shall have the right to annul this contract without liability or to deduct from the contract price or consideration, or otherwise recover, the full amount of the contingent fee.
(b) “Bona fide agency,” as used in this clause, means an established commercial or selling agency, maintained by a contractor for the purpose of securing business, that neither exerts nor proposes to exert improper influence to solicit or obtain Government contracts nor holds itself out as being able to obtain any Government contract or contracts through improper influence.
“Bona fide employee,” as used in this clause, means a person, employed by a contractor and subject to the contractor’s supervision and control as to time, place, and manner of performance, who neither exerts nor proposes to exert improper influence to solicit or obtain Government contracts nor holds out as being able to obtain any Government contract or contracts through improper influence.
“Contingent fee,” as used in this clause, means any commission, percentage, brokerage, or other fee that is contingent upon the success that a person or concern has in securing a Government contract.
“Improper influence,” as used in this clause, means any influence that induces or tends to induce a Government employee or officer to give consideration or to act regarding a Government contract on any basis other than the merits of the matter.

I.4  52.203-6 -- Restrictions on Subcontractor Sales to the Government (Sep 2006)
(a) Except as provided in (b) of this clause, the Contractor shall not enter into any agreement with an actual or prospective subcontractor, nor otherwise act in any manner, which has or may have the effect of restricting sales by such subcontractors directly to the Government of any item or process (including computer software) made or furnished by the subcontractor under this contract or under any follow-on production contract.
(b) The prohibition in (a) of this clause does not preclude the Contractor from asserting rights that are otherwise authorized by law or regulation.
(c) The Contractor agrees to incorporate the substance of this clause, including this paragraph (c), in all subcontracts under this contract which exceed the simplified acquisition threshold.

I.5  52.203-7 -- Anti-Kickback Procedures (May 2014)
(a) Definitions.
“Kickback,” as used in this clause, means any money, fee, commission, credit, gift, gratuity, thing of value, or compensation of any kind which is provided to any prime Contractor, prime Contractor employee, subcontractor, or subcontractor employee for the purpose of improperly obtaining or rewarding favorable treatment in connection with a prime contract or in connection with a subcontract relating to a prime contract.
“Person,” as used in this clause, means a corporation, partnership, business association of any kind, trust, joint-stock company, or individual.
“Prime contract,” as used in this clause, means a contract or contractual action entered into by the United States for the purpose of obtaining supplies, materials, equipment, or services of any kind.
“Prime Contractor” as used in this clause, means a person who has entered into a prime contract with the United States.
“Prime Contractor employee,” as used in this clause, means any officer, partner, employee, or agent of a prime Contractor.
“Subcontract,” as used in this clause, means a contract or contractual action entered into by a prime Contractor or subcontractor for the purpose of obtaining supplies, materials, equipment, or services of any kind under a prime contract.
“Subcontractor,” as used in this clause,
(1) means any person, other than the prime Contractor, who offers to furnish or furnishes any supplies, materials, equipment, or services of any kind under a prime contract or a subcontract entered into in connection with such prime contract, and
(2) includes any person who offers to furnish or furnishes general supplies to the prime Contractor or a higher tier subcontractor.
“Subcontractor employee,” as used in this clause, means any officer, partner, employee, or agent of a subcontractor.
(b) The 41 U.S.C. chapter 87, Kickbacks, prohibits any person from --
(1) Providing or attempting to provide or offering to provide any kickback;
(2) Soliciting, accepting, or attempting to accept any kickback; or
(3) Including, directly or indirectly, the amount of any kickback in the contract price charged by a prime Contractor to the United States or in the contract price charged by a subcontractor to a prime Contractor or higher tier subcontractor.
(c)
(1) The Contractor shall have in place and follow reasonable procedures designed to prevent and detect possible violations described in paragraph (b) of this clause in its own operations and direct business relationships.
(2) When the Contractor has reasonable grounds to believe that a violation described in paragraph (b) of this clause may have occurred, the Contractor shall promptly report in writing the possible violation. Such reports shall be made to the inspector general of the contracting agency, the head of the contracting agency if the agency does not have an inspector general, or the Attorney General.
(3) The Contractor shall cooperate fully with any Federal agency investigating a possible violation described in paragraph (b) of this clause.
(4) The Contracting Officer may
(i) offset the amount of the kickback against any monies owed by the United States under the prime contract and/or
(ii) direct that the Prime Contractor withhold from sums owed a subcontractor under the prime contract the amount of the kickback. The Contracting Officer may order that monies withheld under subdivision (c)(4)(ii) of this clause be paid over to the Government unless the Government has already offset those monies under subdivision (c)(4)(i) of this clause. In either case, the Prime Contractor shall notify the Contracting Officer when the monies are withheld.
(5) The Contractor agrees to incorporate the substance of this clause, including subparagraph (c)(5) but excepting subparagraph (c)(1), in all subcontracts under this contract which exceed $150,000.

I.6  52.203-8 -- Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity (May 2014)
(a) If the Government receives information that a contractor or a person has violated41 U.S.C. 2102-2104, Restriction on Obtaining and Disclosing Certain Information, the Government may --
(1) Cancel the solicitation, if the contract has not yet been awarded or issued; or 
(2) Rescind the contract with respect to which --
(i) The Contractor or someone acting for the Contractor has been convicted for an offense where the conduct violates 41 U.S.C. 2102 for the purpose of either --
(A) Exchanging the information covered by such subsections for anything of value; or
(B) Obtaining or giving anyone a competitive advantage in the award of a Federal agency procurement contract; or
(ii) The head of the contracting activity has determined, based upon a preponderance of the evidence, that the Contractor or someone acting for the Contractor has engaged in conduct punishable under 41 U.S.C. 2105(a).
(b) If the Government rescinds the contract under paragraph (a) of this clause, the Government is entitled to recover, in addition to any penalty prescribed by law, the amount expended under the contract.
(c) The rights and remedies of the Government specified herein are not exclusive, and are in addition to any other rights and remedies provided by law, regulation, or under this contract.

I.7  52.203-10 -- Price or Fee Adjustment for Illegal or Improper Activity (May 2014)
(a) The Government, at its election, may reduce the price of a fixed-price type contract and the total cost and fee under a cost-type contract by the amount of profit or fee determined as set forth in paragraph (b) of this clause if the head of the contracting activity or designee determines that there was a violation of 41 U.S.C. 2102 or 2103, as implemented in section 3.104 of the Federal Acquisition Regulation.
(b) The price or fee reduction referred to in paragraph (a) of this clause shall be --
(1) For cost-plus-fixed-fee contracts, the amount of the fee specified in the contract at the time of award;
(2) For cost-plus-incentive-fee contracts, the target fee specified in the contract at the time of award, notwithstanding any minimum fee or “fee floor” specified in the contract;
(3) For cost-plus-award-fee contracts --
(i) The base fee established in the contract at the time of contract award;
(ii) If no base fee is specified in the contract, 30 percent of the amount of each award fee otherwise payable to the Contractor for each award fee evaluation period or at each award fee determination point.
(4) For fixed-price-incentive contracts, the Government may --
(i) Reduce the contract target price and contract target profit both by an amount equal to the initial target profit specified in the contract at the time of contract award; or
(ii) If an immediate adjustment to the contract target price and contract target profit would have a significant adverse impact on the incentive price revision relationship under the contract, or adversely affect the contract financing provisions, the Contracting Officer may defer such adjustment until establishment of the total final price of the contract. The total final price established in accordance with the incentive price revision provisions of the contract shall be reduced by an amount equal to the initial target profit specified in the contract at the time of contract award and such reduced price shall be the total final contract price.
(5) For firm-fixed-price contracts, by 10 percent of the initial contract price or a profit amount determined by the Contracting Officer from records or documents in existence prior to the date of the contract award.
(c) The Government may, at its election, reduce a prime contractor’s price or fee in accordance with the procedures of paragraph (b) of this clause for violations of the statute by its subcontractors by an amount not to exceed the amount of profit or fee reflected in the subcontract at the time the subcontract was first definitively priced.
(d) In addition to the remedies in paragraphs (a) and (c) of this clause, the Government may terminate this contract for default. The rights and remedies of the Government specified herein are not exclusive, and are in addition to any other rights and remedies provided by law or under this contract.

I.8  52.203-12 -- Limitation on Payments to Influence Certain Federal Transactions (Oct 2010)
(a) Definitions. As used in this clause—
“Agency” means executive agency as defined in Federal Acquisition Regulation (FAR) 2.101.
“Covered Federal action” means any of the following Federal actions:
(1) Awarding any Federal contract.
(2) Making any Federal grant.
(3) Making any Federal loan.
(4) Entering into any cooperative agreement.
(5) Extending, continuing, renewing, amending, or modifying any Federal contract, grant, loan, or cooperative agreement.
“Indian tribe” and “tribal organization” have the meaning provided in section 4 of the Indian Self-Determination and Education Assistance Act (25 U.S.C.450B) and include Alaskan Natives.
“Influencing or attempting to influence” means making, with the intent to influence, any communication to or appearance before an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with any covered Federal action.
“Local government” means a unit of government in a State and, if chartered, established, or otherwise recognized by a State for the performance of a governmental duty, including a local public authority, a special district, an intrastate district, a council of governments, a sponsor group representative organization, and any other instrumentality of a local government.
“Officer or employee of an agency” includes the following individuals who are employed by an agency:
(1) An individual who is appointed to a position in the Government under Title 5, United States Code, including a position under a temporary appointment.
(2) A member of the uniformed services, as defined in subsection 101(3), Title 37, United States Code.
(3) A special Government employee, as defined in section 202, Title 18, United States Code.
(4) An individual who is a member of a Federal advisory committee, as defined by the Federal Advisory Committee Act, Title 5, United States Code, appendix 2.
“Person” means an individual, corporation, company, association, authority, firm, partnership, society, State, and local government, regardless of whether such entity is operated for profit, or not for profit. This term excludes an Indian tribe, tribal organization, or any other Indian organization eligible to receive Federal contracts, grants, cooperative agreements, or loans from an agency, but only with respect to expenditures by such tribe or organization that are made for purposes specified in paragraph (b) of this clause and are permitted by other Federal law.
“Reasonable compensation” means, with respect to a regularly employed officer or employee of any person, compensation that is consistent with the normal compensation for such officer or employee for work that is not furnished to, not funded by, or not furnished in cooperation with the Federal Government.
“Reasonable payment” means, with respect to professional and other technical services, a payment in an amount that is consistent with the amount normally paid for such services in the private sector.
“Recipient” includes the Contractor and all subcontractors. This term excludes an Indian tribe, tribal organization, or any other Indian organization eligible to receive Federal contracts, grants, cooperative agreements, or loans from an agency, but only with respect to expenditures by such tribe or organization that are made for purposes specified in paragraph (b) of this clause and are permitted by other Federal law.
“Regularly employed” means, with respect to an officer or employee of a person requesting or receiving a Federal contract, an officer or employee who is employed by such person for at least 130 working days within 1 year immediately preceding the date of the submission that initiates agency consideration of such person for receipt of such contract. An officer or employee who is employed by such person for less than 130 working days within 1 year immediately preceding the date of the submission that initiates agency consideration of such person shall be considered to be regularly employed as soon as he or she is employed by such person for 130 working days.
“State” means a State of the United States, the District of Columbia, or an outlying area of the United States, an agency or instrumentality of a State, and multi-State, regional, or interstate entity having governmental duties and powers.
(b) Prohibition. 31 U.S.C. 1352 prohibits a recipient of a Federal contract, grant, loan, or cooperative agreement from using appropriated funds to pay any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with any covered Federal actions. In accordance with 31 U.S.C. 1352 the Contractor shall not use appropriated funds to pay any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with the award of this contractor the extension, continuation, renewal, amendment, or modification of this contract.
(1) The term appropriated funds does not include profit or fee from a covered Federal action.
(2) To the extent the Contractor can demonstrate that the Contractor has sufficient monies, other than Federal appropriated funds, the Government will assume that these other monies were spent for any influencing activities that would be unallowable if paid for with Federal appropriated funds.
(c) Exceptions. The prohibition in paragraph (b) of this clause does not apply under the following conditions:
(1) Agency and legislative liaison by Contractor employees. 
(i) Payment of reasonable compensation made to an officer or employee of the Contractor if the payment is for agency and legislative liaison activities not directly related to this contract. For purposes of this paragraph, providing any information specifically requested by an agency or Congress is permitted at any time.
(ii) Participating with an agency in discussions that are not related to a specific solicitation for any covered Federal action, but that concern—
(A) The qualities and characteristics (including individual demonstrations) of the person’s products or services, conditions or terms of sale, and service capabilities; or
(B) The application or adaptation of the person’s products or services for an agency’s use.
(iii) Providing prior to formal solicitation of any covered Federal action any information not specifically requested but necessary for an agency to make an informed decision about initiation of a covered Federal action;
(iv) Participating in technical discussions regarding the preparation of an unsolicited proposal prior to its official submission; and
(v) Making capability presentations prior to formal solicitation of any covered Federal action by persons seeking awards from an agency pursuant to the provisions of the Small Business Act, as amended by Pub. L. 95-507, and subsequent amendments. 
(2) Professional and technical services.
(i) A payment of reasonable compensation made to an officer or employee of a person requesting or receiving a covered Federal action or an extension, continuation, renewal, amendment, or modification of a covered Federal action, if payment is for professional or technical services rendered directly in the preparation, submission, or negotiation of any bid, proposal, or application for that Federal action or for meeting requirements imposed by or pursuant to law as a condition for receiving that Federal action.
(ii) Any reasonable payment to a person, other than an officer or employee of a person requesting or receiving a covered Federal action or an extension, continuation, renewal, amendment, or modification of a covered Federal action if the payment is for professional or technical services rendered directly in the preparation, submission, or negotiation of any bid, proposal, or application for that Federal action or for meeting requirements imposed by or pursuant to law as a condition for receiving that Federal action. Persons other than officers or employees of a person requesting or receiving a covered Federal action include consultants and trade associations.
(iii) As used in this paragraph (c)(2), “professional and technical services” are limited to advice and analysis directly applying any professional or technical discipline (for examples, see FAR 3.803(a)(2)(iii)).
(iv) Requirements imposed by or pursuant to law as a condition for receiving a covered Federal award include those required by law or regulation and any other requirements in the actual award documents.
(3) Only those communications and services expressly authorized by paragraphs (c)(1) and (2) of this clause are permitted.
(d) Disclosure.
(1) If the Contractor did not submit OMB Standard Form LLL, Disclosure of Lobbying Activities, with its offer, but registrants under the Lobbying Disclosure Act of 1995 have subsequently made a lobbying contact on behalf of the Contractor with respect to this contract, the Contractor shall complete and submit OMB Standard Form LLL to provide the name of the lobbying registrants, including the individuals performing the services.
(2) If the Contractor did submit OMB Standard Form LLL disclosure pursuant to paragraph (d) of the provision at FAR 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions, and a change occurs that affects Block 10 of the OMB Standard Form LLL (name and address of lobbying registrant or individuals performing services), the Contractor shall, at the end of the calendar quarter in which the change occurs, submit to the Contracting Officer within 30 days an updated disclosure using OMB Standard Form LLL.
(e) Penalties.
(1) Any person who makes an expenditure prohibited under paragraph (b) of this clause or who fails to file or amend the disclosure to be filed or amended by paragraph (d) of this clause shall be subject to civil penalties as provided for by 31 U.S.C.1352. An imposition of a civil penalty does not prevent the Government from seeking any other remedy that may be applicable.
(2) Contractors may rely without liability on the representation made by their subcontractors in the certification and disclosure form.
(f) Cost allowability. Nothing in this clause makes allowable or reasonable any costs which would otherwise be unallowable or unreasonable. Conversely, costs made specifically unallowable by the requirements in this clause will not be made allowable under any other provision.
(g) Subcontracts.
(1) The Contractor shall obtain a declaration, including the certification and disclosure in paragraphs (c) and (d) of the provision at FAR 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions, from each person requesting or receiving a subcontract exceeding $150,000 under this contract. The Contractor or subcontractor that awards the subcontract shall retain the declaration.
(2) A copy of each subcontractor disclosure form (but not certifications) shall be forwarded from tier to tier until received by the prime Contractor. The prime Contractor shall, at the end of the calendar quarter in which the disclosure form is submitted by the subcontractor, submit to the Contracting Officer within 30 days a copy of all disclosures. Each subcontractor certification shall be retained in the subcontract file of the awarding Contractor.
(3) The Contractor shall include the substance of this clause, including this paragraph (g), in any subcontract exceeding $150,000.

I.9  52.203-13 – Contractor Code of Business Ethics and Conduct (Oct 2015)
(a) Definition. As used in this clause--
“Agent” means any individual, including a director, an officer, an employee, or an independent Contractor, authorized to act on behalf of the organization.
“Full cooperation”—
(1) Means disclosure to the Government of the information sufficient for law enforcement to identify the nature and extent of the offense and the individuals responsible for the conduct. It includes providing timely and complete response to Government auditors’ and investigators’ request for documents and access to employees with information;
(2) Does not foreclose any Contractor rights arising in law, the FAR, or the terms of the contract. It does not require—
(i) A Contractor to waive its attorney-client privilege or the protections afforded by the attorney work product doctrine; or 
(ii) Any officer, director, owner, or employee of the Contractor, including a sole proprietor, to waive his or her attorney client privilege or Fifth Amendment rights; and 
(3) Does not restrict a Contractor from—
(i) Conducting an internal investigation; or
(ii) Defending a proceeding or dispute arising under the contract or related to a potential or disclosed violation.
“Principal” means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).
“Subcontract” means any contract entered into by a subcontractor to furnish supplies or services for performance of a prime contract or a subcontract.
“Subcontractor” means any supplier, distributor, vendor, or firm that furnished supplies or services to or for a prime contractor or another subcontractor.
“United States” means the 50 States, the District of Columbia, and outlying areas.
(b) Code of business ethics and conduct. 
(1) Within 30 days after contract award, unless the Contracting Officer establishes a longer time period, the Contractor shall—
(i) Have a written code of business ethics and conduct; 
(ii) Make a copy of the code available to each employee engaged in performance of the contract.
(2) The Contractor shall—
(i) Exercise due diligence to prevent and detect criminal conduct; and
(ii) Otherwise promote an organizational culture that encourages ethical conduct and a commitment to compliance with the law.
(3) 
(i) The Contractor shall timely disclose, in writing, to the agency Office of the Inspector General (OIG), with a copy to the Contracting Officer, whenever, in connection with the award, performance, or closeout of this contract or any subcontract thereunder, the Contractor has credible evidence that a principal, employee, agent, or subcontractor of the Contractor has committed—
(A) A violation of Federal criminal law involving fraud, conflict of interest, bribery, or gratuity violations found in Title 18 of the United States Code; or
(B) A violation of the civil False Claims Act (31 U.S.C. 3729-3733).
(ii) The Government, to the extent permitted by law and regulation, will safeguard and treat information obtained pursuant to the Contractor’s disclosure as confidential where the information has been marked “confidential” or “proprietary” by the company. To the extent permitted by the law and regulation, such information will not be released by the Government to the public pursuant to a Freedom of Information Act request, 5 U.S.C. Section 552, without prior notification to the Contractor. The Government may transfer documents provided by the Contractor to any department or agency within the Executive Branch if the information relates to matters within the organization’s jurisdiction.
(iii) If the violation relates to an order against a Governmentwide acquisition contract, a multi-agency contract, a multiple-award schedule contract such as the Federal Supply Schedule, or any other procurement instrument intended for use by multiple agencies, the Contractor shall notify the OIG of the ordering agency and the IG of the agency responsible for the basic contract.
(c) Business ethics awareness and compliance program and internal control system. This paragraph (c) does not apply if the Contractor has represented itself as a small business concern pursuant to the award of this contract or if this contract is for the acquisition of a commercial item as defined at FAR 2.101. The Contractor shall establish the following within 90 days after contract award, unless the Contracting Officer establishes a longer time period:
(1) An ongoing business ethics awareness and compliance program.
(i) This program shall include reasonable steps to communicate periodically and in a practical manner the Contractor’s standards and procedures and other aspects of the Contractor’s business ethics awareness and compliance program and internal control system, by conducting effective training programs and otherwise disseminating information appropriate to an individual’s respective roles and responsibilities.
(ii) The training conducted under this program shall be provided to the Contractor’s principals and employees, and as appropriate, the Contractor’s agents and subcontractors.
(2) An internal control system.
(i) The Contractor's internal control system shall—
(A) Establish standards and procedures to facilitate timely discovery of improper conduct in connection with Government contracts; and
(B) Ensure corrective measures are promptly instituted and carried out.
(ii) At a minimum, the Contractor’s internal control system shall provide for the following:
(A) Assignment of responsibility at a sufficiently high level and adequate resources to ensure effectiveness of the business ethics awareness and compliance program and internal control system.
(B) Reasonable efforts not to include an individual as a principal, whom due diligence would have exposed as having engaged in conduct that is in conflict with the Contractor’s code of business ethics and conduct.
(C) Periodic reviews of company business practices, procedures, policies, and internal controls for compliance with the Contractor’s code of business ethics and conduct and special requirements of Government contracting, including—
(1) Monitoring and auditing to detect criminal conduct;
(2) Periodic evaluation of the effectiveness of the business ethics awareness and compliance program and internal control system, especially if criminal conduct has been detected; and
(3) Periodic assessment of the risk of criminal conduct, with appropriate steps to design, implement, or modify the business ethics awareness and compliance program and the internal control system as necessary to reduce the risk of criminal conduct identified through this process.
(D) An internal reporting mechanism, such as a hotline, which allows for anonymity or confidentiality, by which employees may report suspected instances of improper conduct, and instructions that encourage employees to make such reports.
(E) Disciplinary action for improper conduct or for failing to take reasonable steps to prevent or detect improper conduct.
(F) Timely disclosure, in writing, to the agency OIG, with a copy to the Contracting Officer, whenever, in connection with the award, performance, or closeout of any Government contract performed by the Contractor or a subcontractor thereunder, the Contractor has credible evidence that a principal, employee, agent, or subcontractor of the Contractor has committed a violation of Federal criminal law involving fraud, conflict of interest, bribery, or gratuity violations found in Title 18 U.S.C. or a violation of the civil False Claims Act (31 U.S.C. 3729-3733).
(1) If a violation relates to more than one Government contract, the Contractor may make the disclosure to the agency OIG and Contracting Officer responsible for the largest dollar value contract impacted by the violation.
(2) If the violation relates to an order against a Governmentwide acquisition contract, a multi-agency contract, a multiple-award schedule contract such as the Federal Supply Schedule, or any other procurement instrument intended for use by multiple agencies, the contractor shall notify the OIG of the ordering agency and the IG of the agency responsible for the basic contract, and the respective agencies’ contracting officers.
(3) The disclosure requirement for an individual contract continues until at least 3 years after final payment on the contract.
(4) The Government will safeguard such disclosures in accordance with paragraph (b)(3)(ii) of this clause.
(G) Full cooperation with any Government agencies responsible for audits, investigations, or corrective actions.
(d) Subcontracts.
(1) The Contractor shall include the substance of this clause, including this paragraph (d), in subcontracts that have a value in excess of $5.5 million and a performance period of more than 120 days.
(2) In altering this clause to identify the appropriate parties, all disclosures of violation of the civil False Claims Act or of Federal criminal law shall be directed to the agency Office of the Inspector General, with a copy to the Contracting Officer.

I.10  52.203-14 – Display of Hotline Poster(s) (Oct 2015)
(a) Definition.
“United States,” as used in this clause, means the 50 States, the District of Columbia, and outlying areas.
(b) Display of fraud hotline poster(s). Except as provided in paragraph (c)—
(1) During contract performance in the United States, the Contractor shall prominently display in common work areas within business segments performing work under this contract and at contract work sites—
(i) Any agency fraud hotline poster or Department of Homeland Security (DHS) fraud hotline poster identified in paragraph (b)(3) of this clause; and
(ii) Any DHS fraud hotline poster subsequently identified by the Contracting Officer.
(2) Additionally, if the Contractor maintains a company website as a method of providing information to employees, the Contractor shall display an electronic version of the poster(s) at the website.
(3) Any required posters may be obtained as follows:
	
		
	Poster(s)
	Obtain from

	 DOE IG Hotline Poster
	  https://www.energy.gov/sites/prod/files/igprod/documents/Hotline_poster.pdf

(c) If the Contractor has implemented a business ethics and conduct awareness program, including a reporting mechanism, such as a hotline poster, then the Contractor need not display any agency fraud hotline posters as required in paragraph (b) of this clause, other than any required DHS posters.
(d) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (d), in all subcontracts that exceed $5.5 million, except when the subcontract—
(1) Is for the acquisition of a commercial item; or
(2) Is performed entirely outside the United States.

I.11  52.203-17 – Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights (Apr 2014)
(a) This contract and employees working on this contract will be subject to the whistleblower rights and remedies in the pilot program on Contractor employee whistleblower protections established at 41 U.S.C. 4712 by section 828 of the National Defense Authorization Act for Fiscal Year 2013 (Pub. L. 112-239) and FAR 3.908.
(b) The Contractor shall inform its employees in writing, in the predominant language of the workforce, of employee whistleblower rights and protections under 41 U.S.C. 4712, as described in section 3.908 of the Federal Acquisition Regulation.
(c) The Contractor shall insert the substance of this clause, including this paragraph (c), in all subcontracts over the simplified acquisition threshold.

I.12  52.203-19 – Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017)
(a) Definitions. As used in this clause--
“Internal confidentiality agreement or statement” means a confidentiality agreement or any other written statement that the contractor requires any of its employees or subcontractors to sign regarding nondisclosure of contractor information, except that it does not include confidentiality agreements arising out of civil litigation or confidentiality agreements that contractor employees or subcontractors sign at the behest of a Federal agency.
“Subcontract” means any contract as defined in subpart 2.1 entered into by a subcontractor to furnish supplies or services for performance of a prime contract or a subcontract. It includes but is not limited to purchase orders, and changes and modifications to purchase orders.
“Subcontractor” means any supplier, distributor, vendor, or firm (including a consultant) that furnishes supplies or services to or for a prime contractor or another subcontractor.
(b) The Contractor shall not require its employees or subcontractors to sign or comply with internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting waste, fraud, or abuse related to the performance of a Government contract to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information (e.g., agency Office of the Inspector General).
(c) The Contractor shall notify current employees and subcontractors that prohibitions and restrictions of any preexisting internal confidentiality agreements or statements covered by this clause, to the extent that such prohibitions and restrictions are inconsistent with the prohibitions of this clause, are no longer in effect.
(d) The prohibition in paragraph (b) of this clause does not contravene requirements applicable to Standard Form 312 (Classified Information Nondisclosure Agreement), Form 4414 (Sensitive Compartmented Information Nondisclosure Agreement), or any other form issued by a Federal department or agency governing the nondisclosure of classified information.
(e) In accordance with section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015, (Pub. L. 113-235), and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions) use of funds appropriated (or otherwise made available) is prohibited, if the Government determines that the Contractor is not in compliance with the provisions of this clause.
(f) The Contractor shall include the substance of this clause, including this paragraph (f), in subcontracts under such contracts.

I.13 52.204-4 -- Printed or Copied Double-Sided on Postconsumer Fiber Content Paper (May 2011)
(a) Definitions. As used in this clause—
Postconsumer fiber means—
(1) Paper, paperboard, and fibrous materials from retail stores, office buildings, homes, and so forth, after they have passed through their end-usage as a consumer item, including: used corrugated boxes; old newspapers; old magazines; mixed waste paper; tabulating cards; and used cordage; or
(2) All paper, paperboard, and fibrous materials that enter and are collected from municipal solid waste; but not
(3) Fiber derived from printers’ over-runs, converters’ scrap, and over-issue publications.
(b) The Contractor is required to submit paper documents, such as offers, letters, or reports that are printed or copied double-sided on paper containing at least 30 percent postconsumer fiber, whenever practicable, when not using electronic commerce methods to submit information or data to the Government.

I.14  52.204-9 -- Personal Identity Verification of Contractor Personnel (Jan 2011)
(a) The Contractor shall comply with agency personal identity verification procedures identified in the contract that implement Homeland Security Presidential Directive-12 (HSPD-12), Office of Management and Budget (OMB) guidance M-05-24, and Federal Information Processing Standards Publication (FIPS PUB) Number 201.
(b) The Contractor shall account for all forms of Government-provided identification issued to the Contractor employees in connection with performance under this contract. The Contractor shall return such identification to the issuing agency at the earliest of any of the following, unless otherwise determined by the Government;
(1) When no longer needed for contract performance.
(2) Upon completion of the Contractor employee’s employment.
(3) Upon contract completion or termination.
(c) The Contracting Officer may delay final payment under a contract if the Contractor fails to comply with these requirements.
(d) The Contractor shall insert the substance of clause, including this paragraph (d), in all subcontracts when the subcontractor’s employees are required to have routine physical access to a Federally-controlled facility and/or routine access to a Federally-controlled information system. It shall be the responsibility of the prime Contractor to return such identification to the issuing agency in accordance with the terms set forth in paragraph (b) of this section, unless otherwise approved in writing by the Contracting Officer.

I.15  52.204-10 – Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2018)
(a) Definitions. As used in this clause:
“Executive” means officers, managing partners, or any other employees in management positions.
“First-tier subcontract” means a subcontract awarded directly by the Contractor for the purpose of acquiring supplies or services (including construction) for performance of a prime contract. It does not include the Contractor’s supplier agreements with vendors, such as long-term arrangements for materials or supplies that would benefit multiple contracts and/or the costs of which are normally applied to a Contractor’s general and administrative expenses or indirect cost.
“Month of award” means the month in which a contract is signed by the Contracting Officer or the month in which a first-tier subcontract is signed by the Contractor.
“Total compensation” means the cash and noncash dollar value earned by the executive during the Contractor’s preceding fiscal year and includes the following (for more information see 17 CFR 229.402(c)(2)):
(1) Salary and bonus.
(2) Awards of stock, stock options, and stock appreciation rights. Use the dollar amount recognized for financial statement reporting purposes with respect to the fiscal year in accordance with the Financial Accounting Standards Board’s Accounting Standards Codification (FASB ASC) 718, Compensation-Stock Compensation.
(3) Earnings for services under non-equity incentive plans. This does not include group life, health, hospitalization or medical reimbursement plans that do not discriminate in favor of executives, and are available generally to all salaried employees.
(4) Change in pension value. This is the change in present value of defined benefit and actuarial pension plans.
(5) Above-market earnings on deferred compensation which is not tax-qualified.
(6) Other compensation, if the aggregate value of all such other compensation (e.g., severance, termination payments, value of life insurance paid on behalf of the employee, perquisites or property) for the executive exceeds $10,000. 
(b) Section 2(d)(2) of the Federal Funding Accountability and Transparency Act of 2006 (Pub. L. No. 109-282), as amended by section 6202 of the Government Funding Transparency Act of 2008 (Pub. L. 110-252), requires the Contractor to report information on subcontract awards. The law requires all reported information be made public, therefore, the Contractor is responsible for notifying its subcontractors that the required information will be made public.
(c) Nothing in this clause required the disclosure of classified information.
(d)
(1) Executive compensation of the prime contractor. As a part of its annual registration requirement in the System for Award Management (SAM) (FAR provision 52.204-7), the Contractor shall report the names and total compensation of each of the five most highly compensated executives for its preceding completed fiscal year, if—
(i) In the Contractor’s preceding fiscal year, the Contractor received—
(A) 80 percent or more of its annual gross revenues from Federal contracts (and subcontracts), loans, grants (and subgrants), cooperative agreements, and other forms of Federal financial assistance; and
(B) $25,000,000 or more in annual gross revenues from Federal contracts (and subcontracts), loans, grants (and subgrants), cooperative agreements, and other forms of Federal financial assistance; and
(ii) The public does not have access to information about the compensation of the executives through periodic reports filed under section 13(a) or 15(d) of the Securities Exchange Act of 1934 (15 U.S.C. 78m(a), 78o(d)) or section 6104 of the Internal Revenue Code of 1986. (To determine if the public has access to the compensation information, see the U.S. Security and Exchange Commission total compensation filings at http://www.sec.gov/answers/execomp.htm.)
(2) First-tier subcontract information. Unless otherwise directed by the contracting officer, or as provided in paragraph (g) of this clause, by the end of the month following the month of award of a first-tier subcontract with a value of $30,000 or more, the Contractor shall report the following information at http://www.fsrs.gov for that first tier subcontract. (The Contractor shall follow the instruction at http://www.fsrs.gov to report the data.)
(i) Unique entity identifier for the subcontractor receiving the award and for the subcontractor’s parent company, if the subcontractor has a parent company.
(ii) Name of the subcontractor.
(iii) Amount of the subcontract award.
(iv) Date of the subcontract award.
(v) A description of the products or services (including construction) being provided under the subcontract, including the overall purpose and expected outcomes or results of the subcontract.
(vi) Subcontract number (the subcontract number assigned by the Contractor).
(vii) Subcontractor’s physical address including street address, city, state, and country. Also include the nine-digit zip code and congressional district.
(viii) Subcontractor’s primary performance location including street address, city, state, and country. Also include the nine-digit zip code and congressional district.
(ix) The prime contract number, and order number if applicable.
(x) Awarding agency name and code.
(xi) Funding agency name and code.
(xii) Government contracting office code.
(xiii) Treasury account symbol (TAS) as reported in FPDS.
(xiv) The applicable North American Industry Classification System code (NAICS).
(3) Executive compensation of the first-tier subcontractor. Unless otherwise directed by the Contracting Officer, by the end of the month following the month of award of a first-tier subcontract with a value of $30,000 or more, and annually thereafter (calculated from the prime contract award date), the Contractor shall report the names and total compensation of each of the five most highly compensated executives for that first-tier subcontractor for the first-tier subcontractor’s preceding completed fiscal year at https://www.fsrs.gov , if—
(i) In the subcontractor’s preceding fiscal year, the subcontractor received—
(A) 80 percent or more of its annual gross revenues from Federal contracts (and subcontracts), loans, grants (and subgrants), cooperative agreements, and other forms of Federal financial assistance; and
(B) $25,000,000 or more in annual gross revenues from Federal contracts (and subcontracts), loans, grants (and subgrants), cooperative agreements and other forms of Federal financial assistance; and
(ii) The public does not have access to information about the compensation of the executives through periodic reports filed under section 13(a) or 15(d) of the Securities Exchange Act of 1934 (15 U.S.C. 78m(a), 78o(d)) or section 6104 of the Internal Revenue Code of 1986. (To determine if the public has access to the compensation information, see the U.S. Security and Exchange Commission total compensation filings at http://www.sec.gov/answers/execomp.htm.)
(e) The Contractor shall not split or break down first-tier subcontract awards to a value less than $30,000 to avoid the reporting requirements in paragraph (d) of this clause.
(f) The Contractor is required to report information on a first-tier subcontract covered by paragraph (d) when the subcontract is awarded. Continued reporting on the same subcontract is not required unless one of the reported data elements changes during the performance of the subcontract. The Contractor is not required to make further reports after the first-tier subcontract expires.
(g)
(1) If the Contractor in the previous tax year had gross income, from all sources, under $300,000, the Contractor is exempt from the requirement to report subcontractor awards.
(2) If a subcontractor in the previous tax year had gross income from all sources under $300,000, the Contractor does not need to report awards for that subcontractor
(h) The FSRS database at http://www.fsrs.gov will be prepopulated with some information from SAM and the FPDS database. If FPDS information is incorrect, the contractor should notify the contracting officer. If the SAM information is incorrect, the contractor is responsible for correcting this information.

I.16  52.204-13 – System for Award Management Maintenance (Oct 2018)
(a) Definition. As used in this clause--
“Electronic Funds Transfer (EFT) indicator” means a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the commercial, nonprofit, or Government entity to establish additional System for Award Management (SAM) records for identifying alternative EFT accounts (see subpart 32.11) for the same entity.
“Registered in the System for Award Management (SAM)” means that—
(1) The Contractor has entered all mandatory information, including the unique entity identifier and the EFT indicator (if applicable), the Commercial and Government Entity (CAGE) code, as well as data required by the Federal Funding Accountability and Transparency Act of 2006 (see subpart 4.14), into the SAM;
(2) The Contractor has completed the Core, Assertions, Representations and Certifications, and Points of Contact sections of the registration in the SAM;
(3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The Contractor will be required to provide consent for TIN validation to the Government as a part of the SAM registration process; and
(4) The Government has marked the record “Active”.
“System for Award Management (SAM)” means the primary Government repository for prospective Federal awardee and Federal awardee information and the centralized Government system for certain contracting, grants, and other assistance-related processes. It includes—
(1) Data collected from prospective Federal awardees required for the conduct of business with the Government;
(2) Prospective contractor-submitted annual representations and certifications in accordance with FAR subpart 4.12; and
(3) Identification of those parties excluded from receiving Federal contracts, certain subcontracts, and certain types of Federal financial and non-financial assistance and benefits.
“Unique entity identifier” means a number or other identifier used to identify a specific commercial, nonprofit, or Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers.
(b) If the solicitation for this contract contained the provision 52.204-7 with its Alternate I, and the Contractor was unable to register prior to award, the Contractor shall be registered in SAM within 30 days after award or before three days prior to submission of the first invoice, whichever occurs first.
(c) The Contractor shall maintain registration in SAM during contract performance and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement. The Contractor is responsible for the currency, accuracy and completeness of the data within SAM, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in SAM after the initial registration, the Contractor is required to review and update on an annual basis, from the date of initial registration or subsequent updates, its information in SAM to ensure it is current, accurate and complete. Updating information in SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document.
(d)
(1)
(i) If a Contractor has legally changed its business name or ``doing business as'' name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to--
(A) Change the name in the SAM;
(B) Comply with the requirements of subpart 42.12 of the FAR; and
(C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor shall provide with the notification sufficient documentation to support the legally changed name.
(ii) If the Contractor fails to comply with the requirements of paragraph (d)(1)(i) of this clause, or fails to perform the agreement at paragraph (d)(1)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the “Suspension of Payment” paragraph of the electronic funds transfer (EFT) clause of this contract.
(2) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims (see FAR subpart 32.8, Assignment of Claims). Assignees shall be separately registered in SAM. Information provided to the Contractor’s SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the “Suspension of Payment” paragraph of the EFT clause of this contract.
(3) The Contractor shall ensure that the unique entity identifier is maintained with the entity designated at www.sam.gov for establishment of the unique entity identifier throughout the life of the contract. The Contractor shall communicate any change to the unique entity identifier to the Contracting Officer within 30 days after the change, so an appropriate modification can be issued to update the data on the contract. A change in the unique entity identifier does not necessarily require a novation be accomplished.
(e) Contractors may obtain additional information on registration and annual confirmation requirements at https://www.sam.gov. 

I.17  52.204-14 – Service Contract Reporting Requirements (Oct 2016)
(a) Definition. 
“First-tier subcontract” means a subcontract awarded directly by the Contractor for the purpose of acquiring supplies or services (including construction) for performance of a prime contract. It does not include the Contractor’s supplier agreements with vendors, such as long-term arrangements for materials or supplies that benefit multiple contracts and/or the costs of which are normally applied to a Contractor’s general and administrative expenses or indirect costs.
(b) The Contractor shall report, in accordance with paragraphs (c) and (d) of this clause, annually by October 31, for services performed under this contract during the preceding Government fiscal year (October 1-September 30).
(c) The Contractor shall report the following information:
(1) Contract number and, as applicable, order number.
(2) The total dollar amount invoiced for services performed during the previous Government fiscal year under the contract.
(3) The number of Contractor direct labor hours expended on the services performed during the previous Government fiscal year.
(4) Data reported by subcontractors under paragraph (f) of this clause.
(d) The information required in paragraph (c) of this clause shall be submitted via the internet at www.sam.gov. (See SAM User Guide). If the Contractor fails to submit the report in a timely manner, the contracting officer will exercise appropriate contractual remedies. In addition, the Contracting Officer will make the Contractor’s failure to comply with the reporting requirements a part of the Contractor’s performance information under FAR subpart 42.15.
(e) Agencies will review Contractor reported information for reasonableness and consistency with available contract information. In the event the agency believes that revisions to the Contractor reported information are warranted, the agency will notify the Contractor no later than November 15. By November 30, the Contractor shall revise the report or document its rationale for the agency.
(f)
(1) The Contractor shall require each first-tier subcontractor providing services under this contract, with subcontract(s) each valued at or above the thresholds set forth in 4.1703(a)(2), to provide the following detailed information to the Contractor in sufficient time to submit the report:
(i) Subcontract number (including subcontractor name and unique entity identifier); and
(ii) The number of first-tier subcontractor direct-labor hours expended on the services performed during the previous Government fiscal year.
(2) The Contractor shall advise the subcontractor that the information will be made available to the public as required by section 743 of Division C of the Consolidated Appropriations Act, 2010.

I.18  52.204-18 Commercial and Government Entity Code Maintenance (Jul 2016)
(a) Definition. As used in this clause—
“Commercial and government Entity (CAGE) code” means—
(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or Government entity, or
(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as the NATO CAGE (NCAGE) code.
(b) Contractors shall ensure that the CAGE code is maintained throughout the life of the contract. For contractors registered in the System for Award Management (SAM), the DLA Commercial and Government Entity (CAGE) Branch shall only modify data received from SAM in the CAGE master file if the contractor initiates those changes via update of its SAM registration. Contractors undergoing a novation or change-of-name agreement shall notify the contracting officer in accordance with subpart 42.12. The contractor shall communicate any change to the CAGE code to the contracting officer within 30 days after the change, so that a modification can be issued to update the CAGE code on the contract.
(c) Contractors located in the United States or its outlying areas that are not registered in SAM shall submit written change requests to the DLA Commercial and Government Entity (CAGE) Branch. Requests for changes shall be provided at https://cage.dla.mil . Change requests to the CAGE master file are accepted from the entity identified by the code.
(d) Contractors located outside the United States and its outlying areas that are not registered in SAM shall contact the appropriate National Codification Bureau (points of contact available at http://www.nato.int/structur/AC/135/main/links/contacts.htm) or NSPA at https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx.
(e) Additional guidance for maintaining CAGE codes is available at https://cage.dla.mil. 

I.19  52.204-19 – Incorporation by Reference of Representations and Certifications (Dec 2014)
The Contractor’s representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

I.20     FAR 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (Jun 2016)
		
	(a)
	Definitions. As used in this clause –

“Covered contractor information system” means an information system that is owned or operated by a contractor that processes, stores, or transmits Federal contract information. 
“Federal contract information” means information, not intended for public release, that is provided by or generated for the Government under a contract to develop or deliver a product or service to the Government, but not including information provided by the Government to the public (such as on public websites) or simple transactional information, such as necessary to process payments.
“Information” means any communication or representation of knowledge such as facts, data, or opinions, in any medium or form, including textual, numerical, graphic, cartographic, narrative, or audiovisual (Committee on National Security Systems Instruction (CNSSI) 4009). 
“Information system” means a discrete set of information resources organized for the collection, processing, maintenance, use, sharing, dissemination, or disposition of information (44 U.S.C. 3502). 
“Safeguarding” means measures or controls that are prescribed to protect information systems.
		
	(b) 
	Safeguarding requirements and procedures. 

		
	(1) 
	The Contractor shall apply the following basic safeguarding requirements and procedures to protect covered contractor information systems. Requirements and procedures for basic safeguarding of covered contractor information systems shall include, at a minimum, the following security controls:

		
	(i) 
	Limit information system access to authorized users, processes acting on behalf of authorized users, or devices (including other information systems).

		
	(ii) 
	Limit information system access to the types of transactions and functions that authorized users are permitted to execute.

		
	(iii) 
	Verify and control/limit connections to and use of external information systems.

		
	(iv) 
	Control information posted or processed on publicly accessible information systems.

		
	(v) 
	Identify information system users, processes acting on behalf of users, or devices.

		
	(vi) 
	Authenticate (or verify) the identities of those users, processes, or devices, as a prerequisite to allowing access to organizational information systems.

		
	(vii) 
	Sanitize or destroy information system media containing Federal Contract Information before disposal or release for reuse.

		
	(viii) 
	Limit physical access to organizational information systems, equipment, and the respective operating environments to authorized individuals.

		
	(ix) 
	Escort visitors and monitor visitor activity; maintain audit logs of physical access; and control and manage physical access devices.

		
	(x) 
	Monitor, control, and protect organizational communications (i.e., information transmitted or received by organizational information systems) at the external boundaries and key internal boundaries of the information systems.

		
	(xi) 
	Implement subnetworks for publicly accessible system components that are physically or logically separated from internal networks.

		
	(xii) 
	Identify, report, and correct information and information system flaws in a timely manner.

		
	(xiii) 
	Provide protection from malicious code at appropriate locations within organizational information systems.

		
	(xiv) 
	Update malicious code protection mechanisms when new releases are available.

		
	(xv) 
	Perform periodic scans of the information system and real-time scans of files from external sources as files are downloaded, opened, or executed.

		
	(2) 
	Other requirements. This clause does not relieve the Contractor of any other specific safeguarding requirements specified by Federal agencies and departments relating to covered contractor information systems generally or other Federal safeguarding requirements for controlled unclassified information (CUI) as established by Executive Order 13556.

		
	(c) 
	Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (c), in subcontracts under this contract (including subcontracts for the acquisition of commercial items, other than commercially available off-the-shelf items), in which the subcontractor may have Federal contract information residing in or transiting through its information system.

I.21  52.204-23-Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018)
Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018)
(a) Definitions. As used in this clause--
Covered article means any hardware, software, or service that--
(1) Is developed or provided by a covered entity;
(2) Includes any hardware, software, or service developed or provided in whole or in part by a covered entity; or
(3) Contains components using any hardware or software developed 
in whole or in part by a covered entity.
Covered entity means--
(1) Kaspersky Lab;
(2) Any successor entity to Kaspersky Lab;
(3) Any entity that controls, is controlled by, or is under common control with Kaspersky Lab; or
(4) Any entity of which Kaspersky Lab has a majority ownership.
(b) Prohibition. Section 1634 of Division A of the National Defense Authorization Act for Fiscal Year 2018 (Pub. L. 115-91) prohibits Government use of any covered article. The Contractor is prohibited from--
(1) Providing any covered article that the Government will use 
on or after October 1, 2018; and
(2) Using any covered article on or after October 1, 2018, in the development of data or deliverables first produced in the performance of the contract.
(c) Reporting requirement. (1) In the event the Contractor identifies a covered article provided to the Government during contract performance, or the Contractor is notified of such by a subcontractor at any tier or any other source, the Contractor shall report, in writing, to the Contracting Officer or, in the case of the Department of Defense, to the website at https://dibnet.dod.mil/. For indefinite delivery contracts, the Contractor shall report to the Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.dod.mil/.
(2) The Contractor shall report the following information pursuant to paragraph (c)(1) of this clause:
(i) Within 1 business day from the date of such identification or notification: The contract number; the order number(s), if applicable; supplier name; brand; model number (Original Equipment Manufacturer (OEM) number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.
(ii) Within 10 business days of submitting the report pursuant to paragraph (c)(1) of this clause: Any further available information about mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of a covered article, any reasons that led to the use or submission of the covered article, and any additional efforts that will be incorporated to prevent future use or submission of covered articles.
(d) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (d), in all subcontracts, including subcontracts for the acquisition of commercial items.

I.22  52.209-6 -- Protecting the Governments Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Oct 2015)
(a) Definition. “Commercially available off-the-shelf (COTS) item,” as used in this clause--
(1) Means any item of supply (including construction material) that is—
(i) A commercial item (as defined in paragraph (1) of the definition in FAR 2.101);
(ii) Sold in substantial quantities in the commercial marketplace; and
(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and
(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products. 
(b) The Government suspends or debars Contractors to protect the Government’s interests. Other than a subcontract for a commercially available off-the-shelf item, the Contractor shall not enter into any subcontract in excess of $35,000 with a Contractor that is debarred, suspended, or proposed for debarment by any executive agency unless there is a compelling reason to do so.
(c) The Contractor shall require each proposed subcontractor whose subcontract will exceed $35,000, other than a subcontractor providing a commercially available off-the-shelf item, to disclose to the Contractor, in writing, whether as of the time of award of the subcontract, the subcontractor, or its principals, is or is not debarred, suspended, or proposed for debarment by the Federal Government.
(d) A corporate officer or a designee of the Contractor shall notify the Contracting Officer, in writing, before entering into a subcontract with a party (other than a subcontractor providing a commercially available off-the-shelf item) that is debarred, suspended, or proposed for debarment (see FAR 9.404 for information on the System for Award Management (SAM) Exclusions). The notice must include the following:
(1) The name of the subcontractor.
(2) The Contractor’s knowledge of the reasons for the subcontractor being listed with an exclusion in SAM.
(3) The compelling reason(s) for doing business with the subcontractor notwithstanding its being listed with an exclusion in SAM.
(4) The systems and procedures the Contractor has established to ensure that it is fully protecting the Government’s interests when dealing with such subcontractor in view of the specific basis for the party’s debarment, suspension, or proposed debarment.
(e) Subcontracts. Unless this is a contract for the acquisition of commercial items, the Contractor shall include the requirements of this clause, including this paragraph (e) (appropriately modified for the identification of the parties), in each subcontract that—
(1) Exceed $35,000 in value; and
(2) Is not a subcontract for commercially available off-the-shelf items.

I.23  52.209-9 – Updates of Publicly Available Information Regarding Responsibility Matters (Oct 2018)
(a) The Contractor shall update the information in the Federal Awardee Performance and Integrity Information System (FAPIIS) on a semi-annual basis, throughout the life of the contract, by posting the required information in the System for Award Management via https://www.sam.gov.
(b) As required by section 3010 of the Supplemental Appropriations Act, 2010 (Pub. L. 111-212), all information posted in FAPIIS on or after April 15, 2011, except past performance reviews, will be publicly available. FAPIIS consist of two segments—
(1) The non-public segment, into which Government officials and the Contractor post information, which can only be viewed by—
(i) Government personnel and authorized users performing business on behalf of the Government; or
(ii) The Contractor, when viewing data on itself; and
(2) The publicly-available segment, to which all data in the non-public segment of FAPIIS is automatically transferred after a waiting period of 14 calendar days, except for--
(i) Past performance reviews required by subpart 42.15;
(ii) Information that was entered prior to April 15, 2011; or
(iii) Information that is withdrawn during the 14-calendar-day waiting period by the Government official who posted it in accordance with paragraph (c)(1) of this clause.
(c) The Contractor will receive notification when the Government posts new information to the Contractor’s record.
(1) If the Contractor asserts in writing within 7 calendar days, to the Government official who posted the information, that some of the information posted to the non-public segment of FAPIIS is covered by a disclosure exemption under the Freedom of Information Act, the Government official who posted the information must within 7 calendar days remove the posting from FAPIIS and resolve the issue in accordance with agency Freedom of Information procedures, prior to reposting the releasable information. The contractor must cite 52.209-9 and request removal within 7 calendar days of the posting to FAPIIS.
(2) The Contractor will also have an opportunity to post comments regarding information that has been posted by the Government. The comments will be retained as long as the associated information is retained, i.e., for a total period of 6 years. Contractor comments will remain a part of the record unless the Contractor revises them.
(3) As required by section 3010 of Pub. L. 111-212, all information posted in FAPIIS on or after April 15, 2011, except past performance reviews, will be publicly available.
(d) Public requests for system information posted prior to April 15, 2011, will be handled under Freedom of Information Act procedures, including, where appropriate, procedures promulgated under E.O. 12600.

I.24  52.209-10 – Prohibition on Contracting With Inverted Domestic Corporations (Nov 2015)
(a) Definitions. As used in this clause--
“Inverted domestic corporation” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).
“Subsidiary” means an entity in which more than 50 percent of the entity is owned—
(1) Directly by a parent corporation; or
(2) Through another subsidiary of a parent corporation.
(b) If the contractor reorganizes as an inverted domestic corporation or becomes a subsidiary of an inverted domestic corporation at any time during the period of performance of this contract, the Government may be prohibited from paying for Contractor activities performed after the date when it becomes an inverted domestic corporation or subsidiary. The Government may seek any available remedies in the event the Contractor fails to perform in accordance with the terms and conditions of the contract as a result of Government action under this clause.
(c) Exceptions to this prohibition are located at 9.108-2.
(d) In the event the Contractor becomes either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation during contract performance, the Contractor shall give written notice to the Contracting Officer within five business days from the date of the inversion event.

I.25  52.210-1 Market Research (Apr 2011)
(a) Definition. As used in this clause--
“Commercial item and nondevelopmental item” have the meaning contained in Federal acquisition Regulation 2.101.
(b) Before awarding subcontracts over the simplified acquisition threshold for items other than commercial items, the Contractor shall conduct market research to--
(1) Determine if commercial items or, to the extent commercial items suitable to meet the agency’s needs are not available, nondevelopmental items are available that—
(i) Meet the agency’s requirements;
(ii) Could be modified to meet the agency’s requirements; or
(iii) Could meet the agency’s requirements if those requirements were modified to a reasonable extent; and
(2) Determine the extent to which commercial items or nondevelopmental items could be incorporated at the component level.

I.26  52.215-2 -- Audit and Records – Negotiation (Oct 2010)
(a) As used in this clause, “records” includes books, documents, accounting procedures and practices, and other data, regardless of type and regardless of whether such items are in written form, in the form of computer data, or in any other form.
(b) Examination of costs. If this is a cost-reimbursement, incentive, time-and-materials, labor-hour, or price redeterminable contract, or any combination of these, the Contractor shall maintain and the Contracting Officer, or an authorized representative of the Contracting Officer, shall have the right to examine and audit all records and other evidence sufficient to reflect properly all costs claimed to have been incurred or anticipated to be incurred directly or indirectly in performance of this contract. This right of examination shall include inspection at all reasonable times of the Contractor’s plants, or parts of them, engaged in performing the contract.
(c) Certified cost or pricing data. If the Contractor has been required to submit certified cost or pricing data in connection with any pricing action relating to this contract, the Contracting Officer, or an authorized representative of the Contracting Officer, in order to evaluate the accuracy, completeness, and currency of the cost or pricing data, shall have the right to examine and audit all of the Contractor’s records, including computations and projections, related to --
(1) The proposal for the contract, subcontract, or modification;
(2) The discussions conducted on the proposal(s), including those related to negotiating;
(3) Pricing of the contract, subcontract, or modification; or
(4) Performance of the contract, subcontract or modification.
(d) Comptroller General—
(1) The Comptroller General of the United States, or an authorized representative, shall have access to and the right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract or a subcontract hereunder and to interview any current employee regarding such transactions.
(2) This paragraph may not be construed to require the Contractor or subcontractor to create or maintain any record that the Contractor or subcontractor does not maintain in the ordinary course of business or pursuant to a provision of law.
(e) Reports. If the Contractor is required to furnish cost, funding, or performance reports, the Contracting Officer or an authorized representative of the Contracting Officer shall have the right to examine and audit the supporting records and materials, for the purpose of evaluating --
(1) The effectiveness of the Contractor’s policies and procedures to produce data compatible with the objectives of these reports; and
(2) The data reported.
(f) Availability. The Contractor shall make available at its office at all reasonable times the records, materials, and other evidence described in paragraphs (a), (b), (c), (d), and (e) of this clause, for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in Subpart 4.7, Contractor Records Retention, of the Federal Acquisition Regulation (FAR), or for any longer period required by statute or by other clauses of this contract. In addition --
(1) If this contract is completely or partially terminated, the Contractor shall make available the records relating to the work terminated until 3 years after any resulting final termination settlement; and
(2) The Contractor shall make available records relating to appeals under the Disputes clause or to litigation or the settlement of claims arising under or relating to this contract until such appeals, litigation, or claims are finally resolved.
(g) The Contractor shall insert a clause containing all the terms of this clause, including this paragraph (g), in all subcontracts under this contract that exceed the simplified acquisition threshold, and --
(1) That are cost-reimbursement, incentive, time-and-materials, labor-hour, or price-redeterminable type or any combination of these;
(2) For which certified cost or pricing data are required; or
(3) That require the subcontractor to furnish reports as discussed in paragraph (e) of this clause.
The clause may be altered only as necessary to identify properly the contracting parties and the Contracting Officer under the Government prime contract.

I.27  52.215-8 -- Order of Precedence -- Uniform Contract Format (Oct 1997)
Any inconsistency in this solicitation or contract shall be resolved by giving precedence in the following order:
(a) The Schedule (excluding the specifications).
(b) Representations and other instructions.
(c) Contract clauses.
(d) Other documents, exhibits, and attachments.
(e) The specifications. 

I.28  52.215-10 -- Price Reduction for Defective Certified Cost or Pricing Data (Aug 2011)
(a) If any price, including profit or fee, negotiated in connection with this contract, or any cost reimbursable under this contract, was increased by any significant amount because --
(1) The Contractor or a subcontractor furnished certified cost or pricing data that were not complete, accurate, and current as certified in its Certificate of Current Cost or Pricing Data;
(2) A subcontractor or prospective subcontractor furnished the Contractor certified cost or pricing data that were not complete, accurate, and current as certified in the Contractor’s Certificate of Current Cost or Pricing Data; or
(3) Any of these parties furnished data of any description that were not accurate, the price or cost shall be reduced accordingly and the contract shall be modified to reflect the reduction.
(b) Any reduction in the contract price under paragraph (a) of this clause due to defective data from a prospective subcontractor that was not subsequently awarded the subcontract shall be limited to the amount, plus applicable overhead and profit markup, by which (1) the actual subcontract or (2) the actual cost to the Contractor, if there was no subcontract, was less than the prospective subcontract cost estimate submitted by the Contractor; provided, that the actual subcontract price was not itself affected by defective certified cost or pricing data.
(c)
(1) If the Contracting Officer determines under paragraph (a) of this clause that a price or cost reduction should be made, the Contractor agrees not to raise the following matters as a defense:
(i) The Contractor or subcontractor was a sole source supplier or otherwise was in a superior bargaining position and thus the price of the contract would not have been modified even if accurate, complete, and current certified cost or pricing data had been submitted.
(ii) The Contracting Officer should have known that the certified cost or pricing data in issue were defective even though the Contractor or subcontractor took no affirmative action to bring the character of the data to the attention of the Contracting Officer.
(iii) The contract was based on an agreement about the total cost of the contract and there was no agreement about the cost of each item procured under the contract.
(iv) The Contractor or subcontractor did not submit a Certificate of Current Cost or Pricing Data.
(2)
(i) Except as prohibited by subdivision (c)(2)(ii) of this clause, an offset in an amount determined appropriate by the Contracting Officer based upon the facts shall be allowed against the amount of a contract price reduction if --
(A) The Contractor certifies to the Contracting Officer that, to the best of the Contractor’s knowledge and belief, the Contractor is entitled to the offset in the amount requested; and
(B) The Contractor proves that the certified cost or pricing data were available before the “as of” date specified on its Certificate of Current Cost or Pricing Data, and that the data were not submitted before such date.
(ii) An offset shall not be allowed if --
(A) The understated data were known by the Contractor to be understated before the “as of” date specified on its Certificate of Current Cost or Pricing Data; or
(B) The Government proves that the facts demonstrate that the contract price would not have increased in the amount to be offset even if the available data had been submitted before the “as of” date specified on its Certificate of Current Cost or Pricing Data.
(d) If any reduction in the contract price under this clause reduces the price of items for which payment was made prior to the date of the modification reflecting the price reduction, the Contractor shall be liable to and shall pay the United States at the time such overpayment is repaid --
(1) Interest compounded daily, as required by 26 U.S.C. 6622, on the amount of such overpayment to be computed from the date(s) of overpayment to the Contractor to the date the Government is repaid by the Contractor at the applicable underpayment rate effective for each quarter prescribed by the Secretary of the Treasury under 26 U.S.C. 6621(a)(2); and
(2) A penalty equal to the amount of the overpayment, if the Contractor or subcontractor knowingly submitted certified cost or pricing data that were incomplete, inaccurate, or noncurrent.

I.29  52.215-11 -- Price Reduction for Defective Certified Cost or Pricing Data – Modifications (Aug 2011)
(a) This clause shall become operative only for any modification to this contract involving a pricing adjustment expected to exceed the threshold for submission of certified cost or pricing data at FAR 15.403-4, except that this clause does not apply to any modification if an exception under FAR 15.403-1 applies.
(b) If any price, including profit or fee, negotiated in connection with any modification under this clause, or any cost reimbursable under this contract, was increased by any significant amount because
(1) the Contractor or a subcontractor furnished certified cost or pricing data that were not complete, accurate, and current as certified in its Certificate of Current Cost or Pricing Data,
(2) a subcontractor or prospective subcontractor furnished the Contractor certified cost or pricing data that were not complete, accurate, and current as certified in the Contractor’s Certificate of Current Cost or Pricing Data, or
(3) any of these parties furnished data of any description that were not accurate, the price or cost shall be reduced accordingly and the contract shall be modified to reflect the reduction. This right to a price reduction is limited to that resulting from defects in data relating to modifications for which this clause becomes operative under paragraph (a) of this clause.
(c) Any reduction in the contract price under paragraph (b) of this clause due to defective data from a prospective subcontractor that was not subsequently awarded the subcontract shall be limited to the amount, plus applicable overhead and profit markup, by which (1) the actual subcontract or (2) the actual cost to the Contractor, if there was no subcontract, was less than the prospective subcontract cost estimate submitted by the Contractor; provided, that the actual subcontract price was not itself affected by defective certified cost or pricing data.
(d)
(1) If the Contracting Officer determines under paragraph (b) of this clause that a price or cost reduction should be made, the Contractor agrees not to raise the following matters as a defense:
(i) The Contractor or subcontractor was a sole source supplier or otherwise was in a superior bargaining position and thus the price of the contract would not have been modified even if accurate, complete, and current certified cost or pricing data had been submitted.
(ii) The Contracting Officer should have known that the certified cost or pricing data in issue were defective even though the Contractor or subcontractor took no affirmative action to bring the character of the data to the attention of the Contracting Officer.
(iii) The contract was based on an agreement about the total cost of the contract and there was no agreement about the cost of each item procured under the contract.
(iv) The Contractor or subcontractor did not submit a Certificate of Current Cost or Pricing Data.
(2)
(i) Except as prohibited by subdivision (d)(2)(ii) of this clause, an offset in an amount determined appropriate by the Contracting Officer based upon the facts shall be allowed against the amount of a contract price reduction if --
(A) The Contractor certifies to the Contracting Officer that, to the best of the Contractor’s knowledge and belief, the Contractor is entitled to the offset in the amount requested; and
(B) The Contractor proves that the certified cost or pricing data were available before the “as of” date specified on its Certificate of Current Cost or Pricing Data, and that the data were not submitted before such date.
(ii) An offset shall not be allowed if --
(A) The understated data were known by the Contractor to be understated before the “as of” date specified on its Certificate of Current Cost or Pricing Data; or
(B) The Government proves that the facts demonstrate that the contract price would not have increased in the amount to be offset even if the available data had been submitted before the “as of” date specified on its Certificate of Current Cost or Pricing Data.
(e) If any reduction in the contract price under this clause reduces the price of items for which payment was made prior to the date of the modification reflecting the price reduction, the Contractor shall be liable to and shall pay the United States at the time such overpayment is repaid --
(1) Interest compounded daily, as required by 26 U.S.C. 6622, on the amount of such overpayment to be computed from the date(s) of overpayment to the Contractor to the date the Government is repaid by the Contractor at the applicable underpayment rate effective for each quarter prescribed by the Secretary of the Treasury under 26 U.S.C. 6621(a)(2); and
(2) A penalty equal to the amount of the overpayment, if the Contractor or subcontractor knowingly submitted certified cost or pricing data that were incomplete, inaccurate, or noncurrent. 

I.30  52.215-12 Subcontractor Certified Cost or Pricing Data (Deviation 2018-O0015) (MAY 2018)
(a) Unless an exception under FAR 15.403-1 applies, the Contractor shall require the 
subcontractor to submit certified cost or pricing data (actually or by specific identification in 
writing), in accordance with FAR 15.408, Table 15-2 (to include any information reasonably required to explain the subcontractor’s estimating process such as the judgmental factors applied and the mathematical or other methods used in the estimate, including those used in projecting from known data, and the nature and amount of any contingencies included in the price) –
(1) Before awarding any subcontract expected to exceed $750,000 prior to July 1, 2018, or modifying any subcontract that was awarded prior to July 1, 2018, involving a pricing adjustment expected to exceed $750,000, or 
(2) Before awarding any subcontract expected to exceed $2 million on or after July 1, 2018, or modifying any subcontract that was awarded on or after July 1, 2018, involving a pricing adjustment expected to exceed $2 million. 
(b) The Contractor shall require the subcontractor to certify in substantially the form prescribed in FAR 15.406-2 that, to the best of its knowledge and belief, the data submitted under paragraph (a) of this clause were accurate, complete, and current as of the date of agreement on the negotiated price of the subcontract or subcontract modification.
(c) In each subcontract that exceeds the threshold for submission of certified cost or pricing data at FAR 15.403-4, when entered into, the Contractor shall insert either—
(1) The substance of this clause, including this paragraph (c), if paragraph (a) of this clause requires submission of certified cost or pricing data for the subcontract; or
(2) The substance of the clause at FAR 52.215-13, Subcontractor Certified Cost or Pricing Data–Modifications (DEVIATION 2018-O0015).

I.31  52.215-13 Subcontractor Certified Cost or Pricing Data–Modifications (Deviation 2018-O0015) (MAY 2018)
(a) The requirements of paragraphs (b) and (c) of this clause shall—
(1) Become operative only for any modification of a subcontract that was awarded prior to July 1, 2018, involving a pricing adjustment expected to exceed $750,000, or any modification of a subcontract that awarded on or after July 1, 2018, involving a pricing adjustment expected to exceed $2 million; and
(2) Be limited to such modifications.
(b) Unless an exception under FAR 15.403-1 applies, the Contractor shall require the subcontractor to submit certified cost or pricing data (actually or by specific identification in writing), in accordance with FAR 15.408, Table 15-2 (to include any information reasonably required to explain the subcontractor’s estimating process such as the judgmental factors applied and the mathematical or other methods used in the estimate, including those used in projecting from known data, and the nature and amount of any contingencies included in the price)—
(1) Before modifying any subcontract that was awarded prior to July 1, 2018, involving a pricing adjustment expected to exceed $750,000, or
(2) Before modifying any subcontract that was awarded on or after July 1, 2018, involving a pricing adjustment expected to exceed $2 million.
(c) The Contractor shall require the subcontractor to certify in substantially the form prescribed in FAR 15.406-2 that, to the best of its knowledge and belief, the data submitted under paragraph (b) of this clause were accurate, complete, and current as of the date of agreement on the negotiated price of the subcontract or subcontract modification.
(d) The Contractor shall insert the substance of this clause, including this paragraph (d), in each subcontract that exceeds $2 million.

I.32  52.215-14 -- Integrity of Unit Prices (Oct 2010)
(a) Any proposal submitted for the negotiation of prices for items of supplies shall distribute costs within contracts on a basis that ensures that unit prices are in proportion to the items’ base cost (e.g., manufacturing or acquisition costs). Any method of distributing costs to line items that distorts unit prices shall not be used. For example, distributing costs equally among line items is not acceptable except when there is little or no variation in base cost. Nothing in this paragraph requires submission of certified cost or pricing data not otherwise required by law or regulation.
(b) When requested by the Contracting Officer, the Offeror/Contractor shall also identify those supplies that it will not manufacture or to which it will not contribute significant value.
(c) The Contractor shall insert the substance of this clause, less paragraph (b), in all subcontracts for other than: acquisitions at or below the simplified acquisition threshold in FAR Part 2; construction or architect-engineer services under FAR Part 36; utility services under FAR Part 41; services where supplies are not required; commercial items; and petroleum products.

I.33  52.215-15 -- Pension Adjustments and Asset Reversions (Oct 2010)
(a) The Contractor shall promptly notify the Contracting Officer in writing when it determines that it will terminate a defined-benefit pension plan or otherwise recapture such pension fund assets.
(b) For segment closings, pension plan terminations, or curtailment of benefits, the adjustment amount shall be—
(1) For contracts and subcontracts that are subject to full coverage under the Cost Accounting Standards (CAS) Board rules and regulations (48 CFR Chapter 99), the amount measured, assigned, and allocated in accordance with 48 CFR 9904.413-50(c)(12); and
(2) For contracts and subcontracts that are not subject to full coverage under CAS, the amount measured, assigned, and allocated in accordance with 48 CFR 9904.413-50(c)(12), except the numerator of the fraction at 48 CFR 9904.413-50(c)(12)(vi) shall be the sum of the pension plan costs allocated to all non-CAS covered contracts and subcontracts that are subject to Federal Acquisition Regulation (FAR) Subpart 31.2 or for which certified cost or pricing data were submitted.
(c) For all other situations where assets revert to the Contractor, or such assets are constructively received by it for any reason, the Contractor shall, at the Government’s option, make a refund or give a credit to the Government for its equitable share of the gross amount withdrawn. The Government’s equitable share shall reflect the Government’s participation in pension costs through those contracts for which certified cost or pricing data were submitted or that are subject to FAR Subpart 31.2.
(d) The Contractor shall include the substance of this clause in all subcontracts under this contract that meet the applicability requirement of FAR 15.408(g).

I.34  52.215-17 -- Waiver of Facilities Capital Cost of Money (Oct 1997)
The Contractor did not include facilities capital cost of money as a proposed cost of this contract. Therefore, it is an unallowable cost under this contract.

I.35  52.215-18 -- Reversion or Adjustment of Plans for Postretirement Benefits (PRB) Other Than Pensions (Jul 2005)
(a) The Contractor shall promptly notify the Contracting Officer in writing when the Contractor determines that it will terminate or reduce the benefits of a PRB plan.
(b) If PRB fund assets revert or inure to the Contractor, or are constructively received by it under a plan termination or otherwise, the Contractor shall make a refund or give a credit to the Government for its equitable share as required by 31.205-6(o)(5) of the Federal Acquisition Regulation (FAR). When determining or agreeing on the method for recovery of the Government’s equitable share, the contracting parties should consider the following methods: cost reduction, amortizing the credit over a number of years (with appropriate interest), cash refund, or some other agreed upon method. Should the parties be unable to agree on the method for recovery of the Government’s equitable share, through good faith negotiations, the Contracting Officer shall designate the method of recovery.
(c) The Contractor shall insert the substance of this clause in all subcontracts that meet the applicability requirements of FAR 15.408(j).

I.36  52.215-19 -- Notification of Ownership Changes (Oct 1997)
(a) The Contractor shall make the following notifications in writing:
(1) When the Contractor becomes aware that a change in its ownership has occurred, or is certain to occur, that could result in changes in the valuation of its capitalized assets in the accounting records, the Contractor shall notify the Administrative Contracting Officer (ACO) within 30 days.
(2) The Contractor shall also notify the ACO within 30 days whenever changes to asset valuations or any other cost changes have occurred or are certain to occur as a result of a change in ownership.
(b) The Contractor shall --
(1) Maintain current, accurate, and complete inventory records of assets and their costs;
(2) Provide the ACO or designated representative ready access to the records upon request;
(3) Ensure that all individual and grouped assets, their capitalized values, accumulated depreciation or amortization, and remaining useful lives are identified accurately before and after each of the Contractor’s ownership changes; and
(4) Retain and continue to maintain depreciation and amortization schedules based on the asset records maintained before each Contractor ownership change.
(c) The Contractor shall include the substance of this clause in all subcontracts under this contract that meet the applicability requirement of FAR 15.408(k).

I.37  52.215-21 -- Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data – Modifications (Oct 2010)
(a) Exceptions from certified cost or pricing data.
(1) In lieu of submitting certified cost or pricing data for modifications under this contract, for price adjustments expected to exceed the threshold set forth at FAR 15.403-4 on the date of the agreement on price or the date of the award, whichever is later, the Contractor may submit a written request for exception by submitting the information described in the following subparagraphs. The Contracting Officer may require additional supporting information, but only to the extent necessary to determine whether an exception should be granted, and whether the price is fair and reasonable --
(i) Identification of the law or regulation establishing the price offered. If the price is controlled under law by periodic rulings, reviews, or similar actions of a governmental body, attach a copy of the controlling document, unless it was previously submitted to the contracting office.
(ii) Information on modifications of contracts or subcontracts for commercial items.
(A) If --
(1) The original contract or subcontract was granted an exception from certified cost or pricing data requirements because the price agreed upon was based on adequate price competition or prices set by law or regulation, or was a contract or subcontract for the acquisition of a commercial item; and
(2) The modification (to the contract or subcontract) is not exempted based on one of these exceptions, then the Contractor may provide information to establish that the modification would not change the contract or subcontract from a contract or subcontract for the acquisition of a commercial item to a contract or subcontract for the acquisition of an item other than a commercial item.
(B) For a commercial item exception, the Contractor shall provide, at a minimum, information on prices at which the same item or similar items have previously been sold that is adequate for evaluating the reasonableness of the price of the modification. Such information may include --
(1) For catalog items, a copy of or identification of the catalog and its date, or the appropriate pages for the offered items, or a statement that the catalog is on file in the buying office to which the proposal is being submitted. Provide a copy or describe current discount policies and price lists (published or unpublished), e.g., wholesale, original equipment manufacturer, or reseller. Also explain the basis of each offered price and its relationship to the established catalog price, including how the proposed price relates to the price of recent sales in quantities similar to the proposed quantities.
(2) For market-priced items, the source and date or period of the market quotation or other basis for market price, the base amount, and applicable discounts. In addition, describe the nature of the market.
(3) For items included on an active Federal Supply Service Multiple Award Schedule contract, proof that an exception has been granted for the schedule item.
(2) The Contractor grants the Contracting Officer or an authorized representative the right to examine, at any time before award, books, records, documents, or other directly pertinent records to verify any request for an exception under this clause, and the reasonableness of price. For items priced using catalog or market prices, or law or regulation, access does not extend to cost or profit information or other data relevant solely to the Contractor’s determination of the prices to be offered in the catalog or marketplace.
(b) Requirements for certified cost or pricing data. If the Contractor is not granted an exception from the requirement to submit certified cost or pricing data, the following applies:
(1) The Contractor shall submit certified cost or pricing data, data other than certified cost or pricing data, and supporting attachments in accordance with the instruction contained in Table 15-2 of FAR 15.408, which is incorporated by reference with the same force and effect as though it were inserted here in full text. The instructions in Table 15-2 are incorporated as a mandatory format to be used in this contract, unless the Contracting Officer and the Contractor agree to a different format and change this clause to use Alternate I.
(2) As soon as practicable after agreement on price, but before award (except for unpriced actions), the Contractor shall submit a Certificate of Current Cost or Pricing Data, as prescribed by FAR 15.406-2.

I.38  52.215-23 – Limitations on Pass-Through Charges (Oct 2009)
(a) Definitions. As used in this clause--
“Added value” means that the Contractor performs subcontract management functions that the Contracting Officer determines are a benefit to the Government (e.g., processing orders of parts or services, maintaining inventory, reducing delivery lead times, managing multiple sources for contract requirements, coordinating deliveries, performing quality assurance functions).
“Excessive pass-through charge,” with respect to a Contractor or subcontractor that adds no or negligible value to a contract or subcontract, means a charge to the Government by the Contractor or subcontractor that is for indirect costs or profit/fee on work performed by a subcontractor (other than charges for the costs of managing subcontracts and any applicable indirect costs and associated profit/fee based on such costs).
“No or negligible value” means the Contractor or subcontractor cannot demonstrate to the Contracting Officer that its effort added value to the contract or subcontract in accomplishing the work performed under the contract (including task or delivery orders).
“Subcontract” means any contract, as defined in FAR 2.101, entered into by a subcontractor to furnish supplies or services for performance of the contract or a subcontract. It includes but is not limited to purchase orders, and changes and modifications to purchase orders.
“Subcontractor,” as defined in FAR 44.101, means any supplier, distributor, vendor, or firm that furnishes supplies or services to or for a prime Contractor or another subcontractor.
(b) General. The Government will not pay excessive pass-through charges. The Contracting Officer shall determine if excessive pass-through charges exist.
(c) Reporting. Required reporting of performance of work by the Contractor or a subcontractor. The Contractor shall notify the Contracting Officer in writing if—
(1) The Contractor changes the amount of subcontract effort after award such that it exceeds 70 percent of the total cost of work to be performed under the contract, task order, or delivery order. The notification shall identify the revised cost of the subcontract effort and shall include verification that the Contractor will provide added value; or
(2) Any subcontractor changes the amount of lower-tier subcontractor effort after award such that it exceeds 70 percent of the total cost of the work to be performed under its subcontract. The notification shall identify the revised cost of the subcontract effort and shall include verification that the subcontractor will provide added value as related to the work to be performed by the lower-tier subcontractor(s).
(d) Recovery of excessive pass-through charges. If the Contracting Officer determines that excessive pass-through charges exist;
(1) For other than fixed-price contracts, the excessive pass-through charges are unallowable in accordance with the provisions in FAR subpart 31.2; and
(2) For applicable DoD fixed-price contracts, as identified in 15.408(n)(2)(i)(B), the Government shall be entitled to a price reduction for the amount of excessive pass-through charges included in the contract price.
(e) Access to records.
(1) The Contracting Officer, or authorized representative, shall have the right to examine and audit all the Contractor's records (as defined at FAR 52.215-2(a)) necessary to determine whether the Contractor proposed, billed, or claimed excessive pass-through charges.
(2) For those subcontracts to which paragraph (f) of this clause applies, the Contracting Officer, or authorized representative, shall have the right to examine and audit all the subcontractor's records (as defined at FAR 52.215-2(a)) necessary to determine whether the subcontractor proposed, billed, or claimed excessive pass-through charges.
(f) Flowdown. The Contractor shall insert the substance of this clause, including this paragraph (f), in all cost-reimbursement subcontracts under this contract that exceed the simplified acquisition threshold, except if the contract is with DoD, then insert in all cost-reimbursement subcontracts and fixed-price subcontracts, except those identified in 15.408(n)(2)(i)(B)(2), that exceed the threshold for obtaining cost or pricing data in accordance with FAR 15.403-4.

I.39  52.216-7 -- Allowable Cost and Payment (Aug 2018)
(a) Invoicing. 
(1) The Government will make payments to the Contractor when requested as work progresses, but (except for small business concerns) not more often than once every 2 weeks, in amounts determined to be allowable by the Contracting Officer in accordance with Federal Acquisition Regulation (FAR) Subpart 31.2 in effect on the date of this contract and the terms of this contract. The Contractor may submit to an authorized representative of the Contracting Officer, in such form and reasonable detail as the representative may require, an invoice or voucher supported by a statement of the claimed allowable cost for performing this contract.
(2) Contract financing payments are not subject to the interest penalty provisions of the Prompt Payment Act. Interim payments made prior to the final payment under the contract are contract financing payments, except interim payments if this contract contains Alternate I to the clause at 52.232-25.
(3) The designated payment office will make interim payments for contract financing on the 30th day after the designated billing office receives a proper payment request. In the event that the Government requires an audit or other review of a specific payment request to ensure compliance with the terms and conditions of the contract, the designated payment office is not compelled to make payment by the specified due date.
(b) Reimbursing costs.
(1) For the purpose of reimbursing allowable costs (except as provided in subparagraph (b)(2) of this clause, with respect to pension, deferred profit sharing, and employee stock ownership plan contributions), the term “costs” includes only --
(i) Those recorded costs that, at the time of the request for reimbursement, the Contractor has paid by cash, check, or other form of actual payment for items or services purchased directly for the contract;
(ii) When the Contractor is not delinquent in paying costs of contract performance in the ordinary course of business, costs incurred, but not necessarily paid, for --
(A) Supplies and services purchased directly for the contract and associated financing payments to subcontractors, provided payments determined due will be made—
(1) In accordance with the terms and conditions of a subcontract or invoice; and
(2) Ordinarily within 30 days of the submission of the Contractor’s payment request to the Government;
(B) Materials issued from the Contractor’s inventory and placed in the production process for use on the contract;
(C) Direct labor;
(D) Direct travel;
(E) Other direct in-house costs; and
(F) Properly allocable and allowable indirect costs, as shown in the records maintained by the Contractor for purposes of obtaining reimbursement under Government contracts; and
(iii) The amount of financing payments that have been paid by cash, check or other form of payment to subcontractors.
(2) Accrued costs of Contractor contributions under employee pension plans shall be excluded until actually paid unless—
(i) The Contractor’s practice is to make contributions to the retirement fund quarterly or more frequently; and
(ii) The contribution does not remain unpaid 30 days after the end of the applicable quarter or shorter payment period (any contribution remaining unpaid shall be excluded from the Contractor’s indirect costs for payment purposes).
(3) Notwithstanding the audit and adjustment of invoices or vouchers under paragraph (g) of this clause, allowable indirect costs under this contract shall be obtained by applying indirect cost rates established in accordance with paragraph (d) of this clause.
(4) Any statements in specifications or other documents incorporated in this contract by reference designating performance of services or furnishing of materials at the Contractor’s expense or at no cost to the Government shall be disregarded for purposes of cost-reimbursement under this clause.
(c) Small business concerns. A small business concern may receive more frequent payments than every 2 weeks 
(d) Final indirect cost rates.
(1) Final annual indirect cost rates and the appropriate bases shall be established in accordance with Subpart 42.7 of the Federal Acquisition Regulation (FAR) in effect for the period covered by the indirect cost rate proposal.
(2)
(i) The Contractor shall submit an adequate final indirect cost rate proposal to the Contracting Officer (or cognizant Federal agency official) and auditor within the 6-month period following the expiration of each of its fiscal years. Reasonable extensions, for exceptional circumstances only, may be requested in writing by the Contractor and granted in writing by the Contracting Officer. The Contractor shall support its proposal with adequate supporting data.
(ii) The proposed rates shall be based on the Contractor’s actual cost experience for that period. The appropriate Government representative and the Contractor shall establish the final indirect cost rates as promptly as practical after receipt of the Contractor’s proposal.
(iii) An adequate indirect cost rate proposal shall include the following data unless otherwise specified by the cognizant Federal agency official:
(A) Summary of all claimed indirect expense rates, including pool, base, and calculated indirect rate.
(B) General and Administrative expenses (final indirect cost pool). Schedule of claimed expenses by element of cost as indentified in accounting records (Chart of Accounts).
(C) Overhead expenses (final indirect cost pool). Schedule of claimed expenses by element of cost as identified in accounting records (Chart of Accounts) for each final indirect cost pool.
(D) Occupancy expenses (intermediate indirect cost pool). Schedule of claimed expenses by element of cost as identified in accounting records (Chart of Accounts) and expense reallocation to final indirect cost pools.
(E) Claimed allocation bases, by element of cost, used to distribute indirect costs.
(F) Facilities capital cost of money factors computation.
(G) Reconciliation of books of account (i.e., General Ledger) and claimed direct costs by major cost element.
(H) Schedule of direct costs by contract and subcontract and indirect expense applied at claimed rates, as well as a subsidiary schedule of Government participation percentages in each of the allocation base amounts.
(I) Schedule of cumulative direct and indirect costs claimed and billed by contract and subcontract.
(J) Subcontract information. Listing of subcontracts awarded to companies for which the contractor is the prime or upper-tier contractor (include prime and subcontract numbers; subcontract value and award type; amount claimed during the fiscal year; and the subcontractor name, address, and point of contact information).
(K) Summary of each time-and-materials and labor-hour contract information, including labor categories, labor rates, hours, and amounts; direct materials; other direct costs; and, indirect expense applied at claimed rates.
(L) Reconciliation of total payroll per IRS form 941 to total labor costs distribution.
(M) Listing of decisions/agreements/approvals and description of accounting/organizational changes.
(N) Certificate of final indirect costs (see 52.242-4, Certification of Final Indirect Costs).
(O) Contract closing information for contracts physically completed in this fiscal year (include contract number, period of performance, contract ceiling amounts, contract fee computations, level of effort, and indicate if the contract is ready to close).
(iv) The following supplemental information is not required to determine if a proposal is adequate, but may be required during the audit process:
(A) Comparative analysis of indirect expense pools detailed by account to prior fiscal year and budgetary data.
(B) General organizational information and limitation on allowability of compensation for certain contractor personnel. See 31.205-6(p). Additional salary reference information is available at https://www.whitehouse.gov/wp-content/uploads/2017/11/ContractorCompensationCapContractsAwardedBeforeJune24.pdf and https://www.whitehouse.gov/wp-content/uploads/2017/11/ContractorCompensationCapContractsAwardedafterJune24.pdf.
(C) Identification of prime contracts under which the contractor performs as a subcontractor.
(D) Description of accounting system (excludes contractors required to submit a CAS Disclosure Statement or contractors where the description of the accounting system has not changed from the previous year’s submission).
(E) Procedures for identifying and excluding unallowable costs from the costs claimed and billed (excludes contractors where the procedures have not changes from the previous year’s submission).
(F) Certified financial statements and other financial data (e.g., trial balance, compilation, review, etc).
(G) Management letter from outside CPAs concerning any internal control weaknesses.
(H) Actions that have been and/or will be implemented to correct the weaknesses described in the management letter from subparagraph (G) of this section.
(I) List of all internal audit reports issued since the last disclosure of internal audit reports to the Government.
(J) Annual internal audit plan of scheduled audits to be performed in the fiscal year when the final indirect cost rate submission is made.
(K) Federal and State income tax returns.
(L) Securities and Exchange Commission 10-K annual report.
(M) Minutes from board of directors meetings.
(N) Listing of delay claims and termination claims submitted which contain costs relating to the subject fiscal year.
(O) Contract briefings, which generally include a synopsis of all pertinent contract provisions, such as: Contract type, contract amount, product or service(s) to be provided, contract performance period, rate ceilings, advance approval requirements, pre-contract cost allowability limitations, and billing limitations.
(v) The Contractor shall update the billings on all contracts to reflect the final settled rates and update the schedule of cumulative direct and indirect costs claimed and billed, as required in paragraph (d)(2)(iii)(I) of this sections, within 60 days after settlement of final indirect cost rates.
(3) The Contractor and the appropriate Government representative shall execute a written understanding setting forth the final indirect cost rates. The understanding shall specify
(i) the agreed-upon final annual indirect cost rates,
(ii) the bases to which the rates apply,
(iii) the periods for which the rates apply,
(iv) any specific indirect cost items treated as direct costs in the settlement, and
(v) the affected contract and/or subcontract, identifying any with advance agreements or special terms and the applicable rates.
The understanding shall not change any monetary ceiling, contract obligation, or specific cost allowance or disallowance provided for in this contract. The understanding is incorporated into this contract upon execution.
(4) Failure by the parties to agree on a final annual indirect cost rate shall be a dispute within the meaning of the Disputes clause.
(5) Within 120 days (or longer period if approved in writing by the Contracting Officer) after settlement of the final annual indirect cost rates for all years of a physically complete contract, Contractor shall submit a completion invoice or voucher to reflect the settled amounts and rates. The completion invoice or voucher shall include settled subcontract amounts and rates. The prime contractor is responsible for settling subcontractor amounts and rates included in the completion invoice or voucher and providing status of subcontractor audits to the contracting officer upon request.
(6) 
(i) If the Contractor fails to submit a completion invoice or voucher within the time specified in paragraph (d)(5) of this clause, the Contracting Officer may--
(A) Determine the amounts due to the Contractor under the contract; and
(B) Record this determination in a unilateral modification to the contract.
(ii) This determination constitutes the final decision of the Contracting Officer in accordance with the Disputes clause.
(e) Billing rates. Until final annual indirect cost rates are established for any period, the Government shall reimburse the Contractor at billing rates established by the Contracting Officer or by an authorized representative (the cognizant auditor), subject to adjustment when the final rates are established. These billing rates --
(1) Shall be the anticipated final rates; and
(2) May be prospectively or retroactively revised by mutual agreement, at either party’s request, to prevent substantial overpayment or underpayment.
(f) Quick-closeout procedures. Quick-closeout procedures are applicable when the conditions in FAR 42.708(a) are satisfied.
(g) Audit. At any time or times before final payment, the Contracting Officer may have the Contractor’s invoices or vouchers and statements of cost audited. Any payment may be --
(1) Reduced by amounts found by the Contracting Officer not to constitute allowable costs; or
(2) Adjusted for prior overpayments or underpayments.
(h) Final payment.
(1) Upon approval of a completion invoice or voucher submitted by the Contractor in accordance with paragraph (d)(5) of this clause, and upon the Contractor’s compliance with all terms of this contract, the Government shall promptly pay any balance of allowable costs and that part of the fee (if any) not previously paid.
(2) The Contractor shall pay to the Government any refunds, rebates, credits, or other amounts (including interest, if any) accruing to or received by the Contractor or any assignee under this contract, to the extent that those amounts are properly allocable to costs for which the Contractor has been reimbursed by the Government. Reasonable expenses incurred by the Contractor for securing refunds, rebates, credits, or other amounts shall be allowable costs if approved by the Contracting Officer. Before final payment under this contract, the Contractor and each assignee whose assignment is in effect at the time of final payment shall execute and deliver --
(i) An assignment to the Government, in form and substance satisfactory to the Contracting Officer, of refunds, rebates, credits, or other amounts (including interest, if any) properly allocable to costs for which the Contractor has been reimbursed by the Government under this contract; and
(ii) A release discharging the Government, its officers, agents, and employees from all liabilities, obligations, and claims arising out of or under this contract, except --
(A) Specified claims stated in exact amounts, or in estimated amounts when the exact amounts are not known;
(B) Claims (including reasonable incidental expenses) based upon liabilities of the Contractor to third parties arising out of the performance of this contract; provided, that the claims are not known to the Contractor on the date of the execution of the release, and that the Contractor gives notice of the claims in writing to the Contracting Officer within 6 years following the release date or notice of final payment date, whichever is earlier; and
(C) Claims for reimbursement of costs, including reasonable incidental expenses, incurred by the Contractor under the patent clauses of this contract, excluding, however, any expenses arising from the Contractor’s indemnification of the Government against patent liability.

I.40  52.216-12 -- Cost-Sharing Contract -- No Fee (Apr 1984)
(a) The Government shall not pay to the Contractor a fee for performing this contract.
(b) After paying 80 percent of the Government’s share of the total estimated cost of performance shown in the Schedule, the Contracting Officer may withhold further payment of allowable cost until a reserve is set aside in an amount that the Contracting Officer considers necessary to protect the Government’s interest. This reserve shall not exceed one percent of the Government’s share of the total estimated cost shown in the Schedule or $100,000, whichever is less.

I.41  52.219-6   Notice of Total Small Business Set-Aside (Nov 2011)
(a) Definition. “Small business concern,” as used in this clause, means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the size standards in this solicitation.
(b) Applicability. This clause applies only to--
(1) Contracts that have been totally set aside or reserved for small business concerns; and
(2) Orders set aside for small business concerns under multiple-award contracts as described in 8.405-5 and 16.505(b)(2)(i)(F).*
(c) General.
(1) Offers are solicited only from small business concerns. Offers received from concerns that are not small business concerns shall be considered nonresponsive and will be rejected.
(2) Any award resulting from this solicitation will be made to a small business concern.
(d) Agreement. A small business concern submitting an offer in its own name shall furnish, in performing the contract, only end items manufactured or produced by small business concerns in the United States or its outlying areas. If this procurement is processed under simplified acquisition procedures and the total amount of this contract does not exceed $25,000, a small business concern may furnish the product of any domestic firm. This paragraph does not apply to construction or service contracts.
(End of Clause)

I.42  52.219-14 Limitations on Subcontracting (Jan 2017)
(a) This clause does not apply to the unrestricted portion of a partial set-aside.
(b) Applicability. This clause applies only to--
(1) Contracts that have been set aside or reserved for small business concerns or 8(a) participants;
(2) Part or parts of a multiple-award contract that have been set aside for small business concerns or 8(a) participants; and
(3) Orders set aside for small business or 8(a) participants under multiple-award contracts as described in 8.405-5 and 16.505(b)(2)(i)(F).
(c) By submission of an offer and execution of a contract, the Offeror/Contractor agrees that in performance of the contract in the case of a contract for --
(1) Services (except construction). At least 50 percent of the cost of contract performance incurred for personnel shall be expended for employees of the concern.
(2) Supplies (other than procurement from a nonmanufacturer of such supplies). The concern shall perform work for at least 50 percent of the cost of manufacturing the supplies, not including the cost of materials.
(3) General construction. The concern will perform at least 15 percent of the cost of the contract, not including the cost of materials, with its own employees.
(4) Construction by special trade contractors. The concern will perform at least 25 percent of the cost of the contract, not including the cost of materials, with its own employees.
(End of Clause)

I.43  52.219-28 Post-Award Small Business Program Rerepresentation (Jul 2013)
(a) Definitions. As used in this clause--
Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.
Small business concern means a concern, including its affiliates that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is “not dominant in its field of operation” when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.
(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:
(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.
(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.
(3) For long-term contracts—
(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and
(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.
(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards .
(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.
(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor’s current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.
(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.
(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:
The Contractor represents that it [ ] is, [ ] is not a small business concern under NAICS Code ______________ assigned to contract number ______________.[Contractor to sign and date and insert authorized signer's name and title].
(End of clause)

I.44  52.219-8 -- Utilization of Small Business Concerns (Oct 2018)
(a) Definitions. As used in this contract-- 
"HUBZone small business concern" means a small business concern, certified by the Small Business Administration, that appears on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration. 
“Service-disabled veteran-owned small business concern”—
(1) Means a small business concern—
(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and
(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.
(2) “Service-disabled veteran” means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).
"Small business concern" means a small business as defined pursuant to Section 3 of the Small Business Act and relevant regulations promulgated pursuant thereto. 
"Small disadvantaged business concern, consistent with 13 CFR 124.1002,” means a small business concern under the size standard applicable to the acquisition, that--
(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--
(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and
(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and
(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.
“Veteran-owned small business concern” means a small business concern—
(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and
(2) The management and daily business operations of which are controlled by one or more veterans.
"Women-owned small business concern" means a small business concern-- 
(1) That is at least 51 percent owned by one or more women, or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and 
(2) Whose management and daily business operations are controlled by one or more women.
(b) It is the policy of the United States that small business concerns, veteran-owned small business concerns, service-disabled veteran-owned small business concerns, HUBZone small business concerns, small disadvantaged business concerns, and women-owned small business concerns shall have the maximum practicable opportunity to participate in performing contracts let by any Federal agency, including contracts and subcontracts for subsystems, assemblies, components, and related services for major systems. It is further the policy of the United States that its prime contractors establish procedures to ensure the timely payment of amounts due pursuant to the terms of their subcontracts with small business concerns, veteran-owned small business concerns, service-disabled veteran-owned small business concerns, HUBZone small business concerns, small disadvantaged business concerns, and women-owned small business concerns.
(c) The Contractor hereby agrees to carry out this policy in the awarding of subcontracts to the fullest extent consistent with efficient contract performance. The Contractor further agrees to cooperate in any studies or surveys as may be conducted by the United States Small Business Administration or the awarding agency of the United States as may be necessary to determine the extent of the Contractor's compliance with this clause. 
(d) 
(1) The Contractor may accept a subcontractor’s written representations of its size and socioeconomic status as a small business, small disadvantaged, business, veteran-owned small business, service-disabled veteran-owned small business, or a women-owned small business if the subcontractor represents that the size and socioeconomic status representations with its offer are current, accurate, and complete as of the date of the offer for the subcontract.
(2) The Contractor may accept a subcontractor's representations of its size and socioeconomic status as a small business, small disadvantaged business, veteran-owned small business, service-disabled veteran-owned small business, or a women-owned small business in the System for Award Management (SAM) if--
(i) The subcontractor is registered in SAM; and
(ii) The subcontractor represents that the size and socioeconomic status representations made in SAM are current, accurate and complete as of the date of the offer for the subcontract.
(3) The Contractor may not require the use of SAM for the purposes of representing size or socioeconomic status in connection with a subcontract.
(4) In accordance with 13 CFR 121.411, 124.1015, 125.29, 126.900, and 127.700, a contractor acting in good faith is not liable for misrepresentations made by its subcontractors regarding the subcontractor's size or socioeconomic status.
(5) The Contractor shall confirm that a subcontractor representing itself as a HUBZone small business concern is certified by SBA as a HUBZone small business concern by accessing the System for Award Management or by contacting the SBA. Options for contacting the SBA include—
(i) HUBZone small business database search application Web page at http://dsbs.sba.gov/dsbs/search/dsp_searchhubzone.cfm ; or http://www.sba.gov/hubzone ;
(ii) In writing to the Director/HUB, U.S. Small Business Administration, 409 3rd Street, SW., Washington DC 20416; or
(iii) The SBA HUBZone Help Desk at hubzone@sba.gov .
(End of clause)

I.45  52.222-1 -- Notice to the Government of Labor Disputes (Feb 1997)
If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately give notice, including all relevant information, to the Contracting Officer.

I.46  52.222-2 -- Payment for Overtime Premiums (Jul 1990)
(a) The use of overtime is authorized under this contract if the overtime premium does not exceed *10% for Cost-reimbursement CLINs or the overtime premium is paid for work --
(1) Necessary to cope with emergencies such as those resulting from accidents, natural disasters, breakdowns of production equipment, or occasional production bottlenecks of a sporadic nature;
(2) By indirect-labor employees such as those performing duties in connection with administration, protection, transportation, maintenance, standby plant protection, operation of utilities, or accounting;
(3) To perform tests, industrial processes, laboratory procedures, loading or unloading of transportation conveyances, and operations in flight or afloat that are continuous in nature and cannot reasonably be interrupted or completed otherwise; or
(4) That will result in lower overall costs to the Government.
(b) Any request for estimated overtime premiums that exceeds the amount specified above shall include all estimated overtime for contract completion and shall --
(1) Identify the work unit; e.g., department or section in which the requested overtime will be used, together with present workload, staffing, and other data of the affected unit sufficient to permit the Contracting Officer to evaluate the necessity for the overtime;
(2) Demonstrate the effect that denial of the request will have on the contract delivery or performance schedule;
(3) Identify the extent to which approval of overtime would affect the performance or payments in connection with other Government contracts, together with identification of each affected contract; and
(4) Provide reasons why the required work cannot be performed by using multishift operations or by employing additional personnel.
* Insert either “zero” or the dollar amount agreed to during negotiations. The inserted figure does not apply to the exceptions in subparagraph (a)(1) through (a)(4) of the clause.

I.47  52.222-3 -- Convict Labor (June 2003)
(a) Except as provided in paragraph (b) of this clause, the Contractor shall not employ in the performance of this contract any person undergoing a sentence of imprisonment imposed by any court of a State, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, or the U.S. Virgin Islands.
(b) The Contractor is not prohibited from employing persons--
(1) On parole or probation to work at paid employment during the term of their sentence;
(2) Who have been pardoned or who have served their terms; or
(3) Confined for violation of the laws of any of the States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, or the U.S. Virgin Islands who are authorized to work at paid employment in the community under the laws of such jurisdiction, if--
(i) The worker is paid or is in an approved work training program on a voluntary basis;
(ii) Representatives of local union central bodies or similar labor union organizations have been consulted;
(iii) Such paid employment will not result in the displacement of employed workers, or be applied in skills, crafts, or trades in which there is a surplus of available gainful labor in the locality, or impair existing contracts for services; 
(iv) The rates of pay and other conditions of employment will not be less than those paid or provided for work of a similar nature in the locality in which the work is being performed; and
(v) The Attorney General of the United States has certified that the work-release laws or regulations of the jurisdiction involved are in conformity with the requirements of Executive Order 11755, as amended by Executive Orders 12608 and 12943.

I.48  52.222-4 -- Contract Work Hours and Safety Standards -- Overtime Compensation (May 2018)
(a) Overtime requirements. No Contractor or subcontractor employing laborers or mechanics (see Federal Acquisition Regulation 22.300) shall require or permit them to work over 40 hours in any workweek unless they are paid at least 1 and 1/2 times the basic rate of pay for each hour worked over 40 hours.
(b) Violation; liability for unpaid wages; liquidated damages. The responsible Contractor and subcontractor are liable for unpaid wages if they violate the terms in paragraph (a) of this clause. In addition, the Contractor and subcontractor are liable for liquidated damages payable to the Government. The Contracting Officer will assess liquidated damages at the rate specified at 29 CFR 5.5(b)(2) per affected employee for each calendar day on which the employer required or permitted the employee to work in excess of the standard workweek of 40 hours without paying overtime wages required by the Contract Work Hours and Safety Standards statute (found at 40 U.S.C. chapter 37). In accordance with the Federal Civil Penalties Inflation Adjustment Act of 1990 (28 U.S.C. 2461 Note), the Department of Labor adjusts this civil monetary penalty for inflation no later than January 15 each year.
(c) Withholding for unpaid wages and liquidated damages. The Contracting Officer will withhold from payments due under the contract sufficient funds required to satisfy any Contractor or subcontractor liabilities for unpaid wages and liquidated damages. If amounts withheld under the contract are insufficient to satisfy Contractor or subcontractor liabilities, the Contracting Officer will withhold payments from other Federal or Federally assisted contracts held by the same Contractor that are subject to the Contract Work Hours and Safety Standards statute.
(d) Payrolls and basic records.
(1) The Contractor and its subcontractors shall maintain payrolls and basic payroll records for all laborers and mechanics working on the contract during the contract and shall make them available to the Government until 3 years after contract completion. The records shall contain the name and address of each employee, social security number, labor classifications, hourly rates of wages paid, daily and weekly number of hours worked, deductions made, and actual wages paid. The records need not duplicate those required for construction work by Department of Labor regulations at 29 CFR 5.5(a)(3) implementing the Construction Wage Rate Requirements statute.
(2) The Contractor and its subcontractors shall allow authorized representatives of the Contracting Officer or the Department of Labor to inspect, copy, or transcribe records maintained under paragraph (d)(1) of this clause. The Contractor or subcontractor also shall allow authorized representatives of the Contracting Officer or Department of Labor to interview employees in the workplace during working hours.
(e) Subcontracts. The Contractor shall insert the provisions set forth in paragraphs (a) through (d) of this clause in subcontracts may require or involve the employment of laborers and mechanics and require subcontractors to include these provisions in any such lower-tier subcontracts. The Contractor shall be responsible for compliance by any subcontractor or lower-tier subcontractor with the provisions set forth in paragraphs (a) through (d) of this clause.

I.49  52.222-6 – Construction Wage Rate Requirements (Aug 2018)
(a) Definition.—“Site of the work”—
(1) Means--
(i) The primary site of the work. The physical place or places where the construction called for in the contract will remain when work on it is completed; and
(ii) The secondary site of the work, if any. Any other site where a significant portion of the building or work is constructed, provided that such site is—
(A) Located in the United States; and
(B) Established specifically for the performance of the contract or project;
(2) Except as provided in paragraph (3) of this definition, includes any fabrication plants, mobile factories, batch plants, borrow pits, job headquarters, tool yards, etc., provided—
(i) They are dedicated exclusively, or nearly so, to performance of the contract or project; and
(ii) They are adjacent or virtually adjacent to the “primary site of the work” as defined in paragraph (a)(1)(i), or the “secondary site of the work” as defined in paragraph (a)(1)(ii) of this definition;
(3) Does not include permanent home offices, branch plant establishments, fabrication plants, or tool yards of a Contractor or subcontractor whose locations and continuance in operation are determined wholly without regard to a particular Federal contract or project. In addition, fabrication plants, batch plants, borrow pits, job headquarters, yards, etc., of a commercial or material supplier which are established by a supplier of materials for the project before opening of bids and not on the Project site, are not included in the “site of the work.” Such permanent, previously established facilities are not a part of the “site of the work” even if the operations for a period of time may be dedicated exclusively or nearly so, to the performance of a contract.
(b)
(1) All laborers and mechanics employed or working upon the site of the work will be paid unconditionally and not less often than once a week, and without subsequent deduction or rebate on any account (except such payroll deductions as are permitted by regulations issued by the Secretary of Labor under the Copeland Act (29 CFR Part 3)), the full amount of wages and bona fide fringe benefits (or cash equivalents thereof) due at time of payment computed at rates not less than those contained in the wage determination of the Secretary of Labor which is attached hereto and made a part hereof, or as may be incorporated for a secondary site of the work, regardless of any contractual relationship which may be alleged to exist between the Contractor and such laborers and mechanics. Any wage determination incorporated for a secondary site of the work shall be effective from the first day on which work under the contract was performed at that site and shall be incorporated without any adjustment in contract price or estimated cost. Laborers employed by the construction Contractor or construction subcontractor that are transporting portions of the building or work between the secondary site of the work and the primary site of the work shall be paid in accordance with the wage determination applicable to the primary site of the work.
(2) Contributions made or costs reasonably anticipated for bona fide fringe benefits under section 1(b)(2) of the Construction Wage Rate Requirements statute on behalf of laborers or mechanics are considered wages paid to such laborers or mechanics, subject to the provisions of paragraph (e) of this clause; also, regular contributions made or costs incurred for more than a weekly period (but not less often than quarterly) under plans, funds, or programs which cover the particular weekly period, are deemed to be constructively made or incurred during such period.
(3) Such laborers and mechanics shall be paid not less than the appropriate wage rate and fringe benefits in the wage determination for the classification of work actually performed, without regard to skill, except as provided in the clause entitled Apprentices and Trainees. Laborers or mechanics performing work in more than one classification may be compensated at the rate specified for each classification for the time actually worked therein; provided, that the employer’s payroll records accurately set forth the time spent in each classification in which work is performed.
(4) The wage determination (including any additional classifications and wage rates conformed under paragraph (c) of this clause) and the Construction Wage Rate Requirements (Davis-Bacon Act) poster (WH-1321) shall be posted at all times by the Contractor and its subcontractors at the site of the work in a prominent and accessible place where it can be easily seen by the workers.
(c)
(1) The Contracting Officer shall require that any class of laborers or mechanics which is not listed in the wage determination and which is to be employed under the contract shall be classified in conformance with the wage determination. The Contracting Officer shall approve an additional classification and wage rate and fringe benefits therefor only when all the following criteria have been met:
(i) The work to be performed by the classification requested is not performed by a classification in the wage determination.
(ii) The classification is utilized in the area by the construction industry.
(iii) The proposed wage rate, including any bona fide fringe benefits, bears a reasonable relationship to the wage rates contained in the wage determination.
(2) If the Contractor and the laborers and mechanics to be employed in the classification (if known), or their representatives, and the Contracting Officer agree on the classification and wage rate (including the amount designated for fringe benefits, where appropriate), a report of the action taken shall be sent by the Contracting Officer to the Administrator of the:
Wage and Hour Division 
U.S. Department of Labor 
Washington, DC 20210
The Administrator or an authorized representative will approve, modify, or disapprove every additional classification action within 30 days of receipt and so advise the Contracting Officer or will notify the Contracting Officer within the 30-day period that additional time is necessary.
(3) In the event the Contractor, the laborers or mechanics to be employed in the classification, or their representatives, and the Contracting Officer do not agree on the proposed classification and wage rate (including the amount designated for fringe benefits, where appropriate), the Contracting Officer shall refer the questions, including the views of all interested parties and the recommendation of the Contracting Officer, to the Administrator of the Wage and Hour Division for determination. The Administrator, or an authorized representative, will issue a determination within 30 days of receipt and so advise the Contracting Officer or will notify the Contracting Officer within the 30-day period that additional time is necessary.
(4) The wage rate (including fringe benefits, where appropriate) determined pursuant to subparagraphs (c)(2) and (c)(3) of this clause shall be paid to all workers performing work in the classification under this contract from the first day on which work is performed in the classification.
(d) Whenever the minimum wage rate prescribed in the contract for a class of laborers or mechanics includes a fringe benefit which is not expressed as an hourly rate, the Contractor shall either pay the benefit as stated in the wage determination or shall pay another bona fide fringe benefit or an hourly cash equivalent thereof.
(e) If the Contractor does not make payments to a trustee or other third person, the Contractor may consider as part of the wages of any laborer or mechanic the amount of any costs reasonably anticipated in providing bona fide fringe benefits under a plan or program; provided, That the Secretary of Labor has found, upon the written request of the Contractor, that the applicable standards of the Construction Wage Rate Requirements statute have been met. The Secretary of Labor may require the Contractor to set aside in a separate account assets for the meeting of obligations under the plan or program.

I.50  52.222-7 -- Withholding of Funds (May 2014)
The Contracting Officer shall, upon his or her own action or upon written request of an authorized representative of the Department of Labor, withhold or cause to be withheld from the Contractor under this contract or any other Federal contract with the same Prime Contractor, or any other federally assisted contract subject to prevailing wage requirements, which is held by the same Prime Contractor, so much of the accrued payments or advances as may be considered necessary to pay laborers and mechanics, including apprentices, trainees, and helpers, employed by the Contractor or any subcontractor the full amount of wages required by the contract. In the event of failure to pay any laborer or mechanic, including any apprentice, trainee, or helper, employed or working on the site of the work, all or part of the wages required by the contract, the Contracting Officer may, after written notice to the Contractor, take such action as may be necessary to cause the suspension of any further payment, advance, or guarantee of funds until such violations have ceased.

I.51  52.222-8 -- Payrolls and Basic Records (Aug 2018)
(a) Payrolls and basic records relating thereto shall be maintained by the Contractor during the course of the work and preserved for a period of 3 years thereafter for all laborers and mechanics working at the site of the work. Such records shall contain the name, address, and social security number of each such worker, his or her correct classification, hourly rates of wages paid (including rates of contributions or costs anticipated for bona fide fringe benefits or cash equivalents thereof of the types described in 40 U.S.C. 3141(2)(B) (Construction Wage Rate Requirement statute)), daily and weekly number of hours worked, deductions made, and actual wages paid. Whenever the Secretary of Labor has found, under paragraph (d) of the clause entitled Construction Wage Rate Requirements, that the wages of any laborer or mechanic include the amount of any costs reasonably anticipated in providing benefits under a plan or program described in 40 U.S.C. 3141(2)(B), the Contractor shall maintain records which show that the commitment to provide such benefits is enforceable, that the plan or program is financially responsible, and that the plan or program has been communicated in writing to the laborers or mechanics affected, and records which show the costs anticipated or the actual cost incurred in providing such benefits. Contractors employing apprentices or trainees under approved programs shall maintain written evidence of the registration of apprenticeship programs and certification of trainee programs, the registration of the apprentices and trainees, and the ratios and wage rates prescribed in the applicable programs.
(b)
(1) The Contractor shall submit weekly for each week in which any contract work is performed a copy of all payrolls to the Contracting Officer. The payrolls submitted shall set out accurately and completely all of the information required to be maintained under paragraph (a) of this clause, except that full social security numbers and home addresses shall not be included on weekly transmittals. Instead the payrolls shall only need to include an individually identifying number for each employee (e.g., the last four digits of the employee’s social security number). The required weekly payroll information may be submitted in any form desired. Optional Form WH-347 is available for this purpose and may be obtained from the U.S. Department of Labor Wage and Hour Division website at http://www.dol.gov/whd/forms/wh347.pdf . The Prime Contractor is responsible for the submission of copies of payrolls by all subcontractors. Contractors and subcontractors shall maintain the full social security number and current address of each covered worker, and shall provide them upon request to the Contracting Officer, the Contractor, or the Wage and Hour Division of the Department of Labor for purposes of an investigation or audit of compliance with prevailing wage requirements. It is not a violation of this section for a Prime Contractor to require a subcontractor to provide addresses and social security numbers to the Prime Contractor for its own records, without weekly submission to the Contracting Officer.
(2) Each payroll submitted shall be accompanied by a “Statement of Compliance,” signed by the Contractor or subcontractor or his or her agent who pays or supervises the payment of the persons employed under the contract and shall certify --
(i) That the payroll for the payroll period contains the information required to be maintained under paragraph (a) of this clause and that such information is correct and complete;
(ii) That each laborer or mechanic (including each helper, apprentice, and trainee) employed on the contract during the payroll period has been paid the full weekly wages earned, without rebate, either directly or indirectly, and that no deductions have been made either directly or indirectly from the full wages earned, other than permissible deductions as set forth in the Regulations, 29 CFR Part 3; and
(iii) That each laborer or mechanic has been paid not less than the applicable wage rates and fringe benefits or cash equivalents for the classification of work performed, as specified in the applicable wage determination incorporated into the contract.
(3) The weekly submission of a properly executed certification set forth on the reverse side of Optional Form WH-347 shall satisfy the requirement for submission of the “Statement of Compliance” required by subparagraph (b)(2) of this clause.
(4) The falsification of any of the certifications in this clause may subject the Contractor or subcontractor to civil or criminal prosecution under Section 1001 of Title 18 and Section 3729 of Title 31 of the United States Code.
(c) The Contractor or subcontractor shall make the records required under paragraph (a) of this clause available for inspection, copying, or transcription by the Contracting Officer or authorized representatives of the Contracting Officer or the Department of Labor. The Contractor or subcontractor shall permit the Contracting Officer or representatives of the Contracting Officer or the Department of Labor to interview employees during working hours on the job. If the Contractor or subcontractor fails to submit required records or to make them available, the Contracting Officer may, after written notice to the Contractor, take such action as may be necessary to cause the suspension of any further payment. Furthermore, failure to submit the required records upon request or to make such records available may be grounds for debarment action pursuant to 29 CFR 5.12.

I.52  52.222-9 -- Apprentices and Trainees (Jul 2005)
(a) Apprentices. 
(1) An apprentice will be permitted to work at less than the predetermined rate for the work they performed when they are employed—
(i) Pursuant to and individually registered in a bona fide apprenticeship program registered with the U.S. Department of Labor, Employment and Training Administration, Office of Apprenticeship and Training, Employer, and Labor Services (OATELS) or with a State Apprenticeship Agency recognized by the OATELS; or
(ii) In the first 90 days of probationary employment as an apprentice in such an apprenticeship program, even though not individually registered in the program, if certified by the OATELS or a State Apprenticeship Agency (where appropriate) to be eligible for probationary employment as an apprentice. 
(2) The allowable ratio of apprentices to journeymen on the job site in any craft classification shall not be greater than the ratio permitted to the Contractor as to the entire work force under the registered program.
(3) Any worker listed on a payroll at an apprentice wage rate, who is not registered or otherwise employed as stated in paragraph (a)(1) of this clause, shall be paid not less than the applicable wage determination for the classification of work actually performed. In addition, any apprentice performing work on the job site in excess of the ratio permitted under the registered program shall be paid not less than the applicable wage rate on the wage determination for the work actually performed.
(4) Where a contractor is performing construction on a project in a locality other than that in which its program is registered, the ratios and wage rates (expressed in percentages of the journeyman’s hourly rate) specified in the Contractor’s or subcontractor’s registered program shall be observed. Every apprentice must be paid at not less than the rate specified in the registered program for the apprentice’s level of progress, expressed as a percentage of the journeyman hourly rate specified in the applicable wage determination.
(5) Apprentices shall be paid fringe benefits in accordance with the provisions of the apprenticeship program. If the apprenticeship program does not specify fringe benefits, apprentices must be paid the full amount of fringe benefits listed on the wage determination for the applicable classification. If the Administrator determines that a different practice prevails for the applicable apprentice classification, fringes shall be paid in accordance with that determination.
(6) In the event OATELS, or a State Apprenticeship Agency recognized by OATELS, withdraws approval of an apprenticeship program, the Contractor will no longer be permitted to utilize apprentices at less than the applicable predetermined rate for the work performed until an acceptable program is approved.
(b) Trainees. 
(1) Except as provided in 29 CFR 5.16, trainees will not be permitted to work at less than the predetermined rate for the work performed unless they are employed pursuant to and individually registered in a program which has received prior approval, evidenced by formal certification by the U.S. Department of Labor, Employment and Training Administration, Office of Apprenticeship Training, Employer, and Labor Services (OATELS). The ratio of trainees to journeymen on the job site shall not be greater than permitted under the plan approved by OATELS.
(2) Every trainee must be paid at not less than the rate specified in the approved program for the trainee’s level of progress, expressed as a percentage of the journeyman hourly rate specified in the applicable wage determination. Trainees shall be paid fringe benefits in accordance with the provisions of the trainee program. If the trainee program does not mention fringe benefits, trainees shall be paid the full amount of fringe benefits listed in the wage determination unless the Administrator of the Wage and Hour Division determines that there is an apprenticeship program associated with the corresponding journeyman wage rate in the wage determination which provides for less than full fringe benefits for apprentices. Any employee listed on the payroll at a trainee rate who is not registered and participating in a training plan approved by the OATELS shall be paid not less than the applicable wage rate in the wage determination for the classification of work actually performed. In addition, any trainee performing work on the job site in excess of the ratio permitted under the registered program shall be paid not less than the applicable wage rate in the wage determination for the work actually performed.
(3) In the event OATELS withdraws approval of a training program, the Contractor will no longer be permitted to utilize trainees at less than the applicable predetermined rate for the work performed until an acceptable program is approved.
(c) Equal employment opportunity. The utilization of apprentices, trainees, and journeymen under this clause shall be in conformity with the equal employment opportunity requirements of Executive Order 11246, as amended, and 29 CFR Part 30.

I.53  52.222-10 -- Compliance with Copeland Act Requirements (Feb 1988)
The Contractor shall comply with the requirements of 29 CFR Part 3, which are hereby incorporated by reference in this contract.

I.54  52.222-11 -- Subcontracts (Labor Standards) (May 2014)
(a) Definition. “Construction, alteration or repair,” as used in this clause means all types of work done by laborers and mechanics employed by the construction Contractor or construction subcontractor on a particular building or work at the site thereof, including without limitation—
(1) Altering, remodeling, installation (if appropriate) on the site of the work of items fabricated off-site;
(2) Painting and decorating;
(3) Manufacturing or furnishing of materials, articles, supplies, or equipment on the site of the building or work;
(4) Transportation of materials and supplies between the site of the work within the meaning of paragraphs (a)(1)(i) and (ii) of the “site of the work” as defined in the FAR clause at 52.222-6, Construction Wage Rate Requirements of this contract, and a facility which is dedicated to the construction of the building or work and is deemed part of the site of the work within the meaning of paragraph (2) of the “site of the work” definition; and
(5) Transportation of portions of the building or work between a secondary site where a significant portion of the building or work is constructed, which is part of the “site of the work” definition in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, and the physical place or places where the building or work will remain (paragraph (a)(1)(i) of the FAR clause at 52.222-6, in the “site of the work” definition).
(b) The Contractor or subcontractor shall insert in any subcontracts for construction, alterations and repairs within the United States the clauses entitled—
(1) Construction Wage Rate Requirements;
(2) Contract Work Hours and Safety Standards -- Overtime Compensation (if the clause is included in this contract);
(3) Apprentices and Trainees;
(4) Payrolls and Basic Records;
(5) Compliance with Copeland Act Requirements;
(6) Withholding of Funds;
(7) Subcontracts (Labor Standards);
(8) Contract Termination – Debarment;
(9) Disputes Concerning Labor Standards;
(10) Compliance with Construction Wage Rate Requirements and Related Regulations; and
(11) Certification of Eligibility.
(c) The Prime Contractor shall be responsible for compliance by any subcontractor or lower tier subcontractor performing construction within the United States with all the contract clauses cited in paragraph (b).
(d)
(1) Within 14 days after award of the contract, the Contractor shall deliver to the Contracting Officer a completed Standard Form (SF) 1413, Statement and Acknowledgment, for each subcontract for construction within the United States, including the subcontractor’s signed and dated acknowledgment that the clauses set forth in paragraph (b) of this clause have been included in the subcontract.
(2) Within 14 days after the award of any subsequently awarded subcontract the Contractor shall deliver to the Contracting Officer an updated completed SF 1413 for such additional subcontract.
(e) The Contractor shall insert the substance of this clause, including this paragraph (e) in all subcontracts for construction within the United States.

I.55  52.222-12 -- Contract Termination – Debarment (May 2014)
A breach of the contract clauses entitled Construction Wage Rate Requirements, Contract Work Hours and Safety Standards -- Overtime Compensation, Apprentices and Trainees, Payrolls and Basic Records, Compliance with Copeland Act Requirements, Subcontracts (Labor Standards), Compliance with Construction Wage Rate Requirements and Related Regulations, or Certification of Eligibility may be grounds for termination of the contract, and for debarment as a Contractor and subcontractor as provided in 29 CFR 5.12.

I.56  52.222-13 -- Compliance with Construction Wage Rate Requirements and Related Regulations (May 2014)
All rulings and interpretations of the Construction Wage Rate Requirements and related statutes contained in 29 CFR Parts 1, 3, and 5 are hereby incorporated by reference in this contract.

I.57  52.222-14 -- Disputes Concerning Labor Standards (Feb 1988)
The United States Department of Labor has set forth in 29 CFR Parts 5, 6, and 7 procedures for resolving disputes concerning labor standards requirements. Such disputes shall be resolved in accordance with those procedures and not the Disputes clause of this contract. Disputes within the meaning of this clause include disputes between the Contractor (or any of its subcontractors) and the contracting agency, the U.S. Department of Labor, or the employees or their representatives.

I.58  52.222-15 -- Certification of Eligibility (May 2014)
(a) By entering into this contract, the Contractor certifies that neither it nor any person or firm who has an interest in the Contractor’s firm is a person or firm ineligible to be awarded Government contracts by virtue of 40 U.S.C. 3144(b)(2) or 29 CFR 5.12(a)(1).
(b) No part of this contract shall be subcontracted to any person or firm ineligible for award of a Government contract by virtue of 40 U.S.C. 3144(b)(2) or 29 CFR 5.12(a)(1).
(c) The penalty for making false statements is prescribed in the U.S. Criminal Code, 18 U.S.C. 1001.

I.59  52.222-16 -- Approval of Wage Rates (May 2014)
All straight time wage rates, and overtime rates based thereon, for laborers and mechanics engaged in work under this contract must be submitted for approval in writing by the head of the contracting activity or a representative expressly designated for this purpose, if the straight time wages exceed the rates for corresponding classifications contained in the applicable Construction Wage Rate Requirements minimum wage determination included in the contract. Any amount paid by the Contractor to any laborer or mechanic in excess of the agency approved wage rate shall be at the expense of the Contractor and shall not be reimbursed by the Government. If the Government refuses to authorize the use of the overtime, the Contractor is not released from the obligation to pay employees at the required overtime rates for any overtime actually worked.

I.60  52.222-21 -- Prohibition of Segregated Facilities (Apr 2015)
(a) Definitions. As used in this clause--
“Gender identity” has the meaning given by the Department of Labor’s Office of Federal Contract Compliance Programs, and is found at www.dol.gov/ofccp/LGBT/LGBT_FAQs.html .
“Segregated facilities” means any waiting rooms, work areas, rest rooms and wash rooms, restaurants and other eating areas, time clocks, locker rooms and other storage or dressing areas, parking lots, drinking fountains, recreation or entertainment areas, transportation, and housing facilities provided for employees, that are segregated by explicit directive or are in fact segregated on the basis of race, color, religion, sex, sexual orientation, gender identity, or national origin because of written or oral policies or employee custom. The term does not include separate or single-user rest rooms or necessary dressing or sleeping areas provided to assure privacy between sexes.
“Sexual orientation” has the meaning given by the Department of Labor’s Office of Federal Contract Compliance Programs, and is found at www.dol.gov/ofccp/LGBT/LGBT_FAQs.html .
(b) The contractor agrees that it does not and will not maintain or provide for its employees any segregated facilities at any of its establishments, and that it does not and will not permit its employees to perform their services at any location under its control where segregated facilities are maintained. The Contractor agrees that a breach of this clause is a violation of the Equal Opportunity clause in the contract.
(c) The Contractor shall include this clause in every subcontract and purchase order that is subject to the Equal Opportunity clause of this contract.

I.61  52.222-26 -- Equal Opportunity (Sep 2016)
(a) Definitions. As used in this clause--
“Compensation” means any payments made to, or on behalf of , an employee or offered to an applicant as remuneration for employment, including but not limited to salary, wages, overtime pay, shift differentials, bonuses, commissions, vacation and holiday pay, allowances, insurance and other benefits, stock options and awards, profit sharing, and retirement.
“Compensation information” means the amount and type of compensation provided to employees or offered to applicants, including, but not limited to, the desire of the Contractor to attract and retain a particular employee for the value the employee is perceived to add to the Contractor’s profit or productivity; the availability of employees with like skills in the marketplace; market research about the worth of similar jobs in the relevant marketplace; job analysis, descriptions, and evaluations; salary and pay structures; salary surveys; labor union agreements; and Contractor decisions, statements and policies related to setting or altering employee compensation. 
“Essential job functions” means the fundamental job duties of the employment position an individual holds. A job function may be considered essential if—
(1) The access to compensation information is necessary in order to perform that function or another routinely assigned business task; or
(2) The function or duties of the position include protecting and maintaining the privacy of employee personnel records, including compensation information.
“Gender identity” has the meaning given by the Department of Labor’s Office of Federal Contract Compliance Programs, and is found at www.dol.gov/ofccp/LGBT/LGBT_FAQs.html .
“Sexual orientation” has the meaning given by the Department of Labor’s Office of Federal Contract Compliance Programs, and is found at www.dol.gov/ofccp/LGBT/LGBT_FAQs.html .
“United States” means the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.
(b) 
(1) If, during any 12-month period (including the 12 months preceding the award of this contract), the Contractor has been or is awarded nonexempt Federal contracts and/or subcontracts that have an aggregate value in excess of $10,000, the Contractor shall comply with this clause, except for work performed outside the United States by employees who were not recruited within the United States. Upon request, the Contractor shall provide information necessary to determine the applicability of this clause.
(2) If the Contractor is a religious corporation, association, educational institution, or society, the requirements of this clause do not apply with respect to the employment of individuals of a particular religion to perform work connected with the carrying on of the Contractor’s activities (41 CFR 60-1.5).
(c)
(1) The Contractor shall not discriminate against any employee or applicant for employment because of race, color, religion, sex, sexual orientation, gender identity, or national origin. However, it shall not be a violation of this clause for the Contractor to extend a publicly announced preference in employment to Indians living on or near an Indian reservation, in connection with employment opportunities on or near an Indian reservation, as permitted by 41 CFR 60-1.5.
(2) The Contractor shall take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, color, religion, sex, sexual orientation, gender identity, or national origin. This shall include, but not be limited to --
(i) Employment;
(ii) Upgrading;
(iii) Demotion;
(v) Transfer;
(v) Recruitment or recruitment advertising;
(vi) Layoff or termination;
(vii) Rates of pay or other forms of compensation; and
(viii) Selection for training, including apprenticeship.
(3) The Contractor shall post in conspicuous places available to employees and applicants for employment the notices to be provided by the Contracting Officer that explain this clause.
(4) The Contractor shall, in all solicitations or advertisements for employees placed by or on behalf of the Contractor, state that all qualified applicants will receive consideration for employment without regard to race, color, religion, sex, sexual orientation, gender identity, or national origin.
(5) 
(i) The Contractor shall not discharge or in any other manner discriminate against any employee or applicant for employment because such employee or applicant has inquired about, discussed, or disclosed the compensation of the employee or applicant or another employee or applicant. This prohibition against discrimination does not apply to instances in which an employee who has access to the compensation information of other employees or applicants as a part of such employee's essential job functions discloses the compensation of such other employees or applicants to individuals who do not otherwise have access to such information, unless such disclosure is in response to a formal complaint or charge, in furtherance of an investigation, proceeding, hearing, or action, including an investigation conducted by the employer, or is consistent with the Contractor's legal duty to furnish information.
(ii) The Contractor shall disseminate the prohibition on discrimination in paragraph (c)(5)(i) of this clause, using language prescribed by the Director of the Office of Federal Contract Compliance Programs (OFCCP), to employees and applicants by--
(A) Incorporation into existing employee manuals or handbooks; and
(B) Electronic posting or by posting a copy of the provision in conspicuous places available to employees and applicants for employment.
(6) The Contractor shall send, to each labor union or representative of workers with which it has a collective bargaining agreement or other contract or understanding, the notice to be provided by the Contracting Officer advising the labor union or workers’ representative of the Contractor’s commitments under this clause, and post copies of the notice in conspicuous places available to employees and applicants for employment.
(7) The Contractor shall comply with Executive Order 11246, as amended, and the rules, regulations, and orders of the Secretary of Labor.
(8) The Contractor shall furnish to the contracting agency all information required by Executive Order 11246, as amended, and by the rules, regulations, and orders of the Secretary of Labor. The Contractor shall also file Standard Form 100 (EEO-1), or any successor form, as prescribed in 41 CFR part 60-1. Unless the Contractor has filed within the 12 months preceding the date of contract award, the Contractor shall, within 30 days after contract award, apply to either the regional Office of Federal Contract Compliance Programs (OFCCP) or the local office of the Equal Employment Opportunity Commission for the necessary forms.
(9) The Contractor shall permit access to its premises, during normal business hours, by the contracting agency or the (OFCCP) for the purpose of conducting on-site compliance evaluations and complaint investigations. The Contractor shall permit the Government to inspect and copy any books, accounts, records (including computerized records), and other material that may be relevant to the matter under investigation and pertinent to compliance with Executive Order 11246, as amended, and rules and regulations that implement the Executive Order.
(10) If the OFCCP determines that the Contractor is not in compliance with this clause or any rule, regulation, or order of the Secretary of Labor, this contract may be canceled, terminated, or suspended in whole or in part and the Contractor may be declared ineligible for further Government contracts, under the procedures authorized in Executive Order 11246, as amended. In addition, sanctions may be imposed and remedies invoked against the Contractor as provided in Executive Order 11246, as amended, in the rules, regulations, and orders of the Secretary of Labor, or as otherwise provided by law.
(11) The Contractor shall include the terms and conditions of this clause in every subcontract or purchase order that is not exempted by the rules, regulations, or orders of the Secretary of Labor issued under Executive Order 11246, as amended, so that these terms and conditions will be binding upon each subcontractor or vendor.
(12) The Contractor shall take such action with respect to any subcontract or purchase order as the Director of OFCCP may direct as a means of enforcing these terms and conditions, including sanctions for noncompliance; provided, that if the Contractor becomes involved in, or is threatened with, litigation with a subcontractor or vendor as a result of any direction, the Contractor may request the United States to enter into the litigation to protect the interests of the United States.
(d) Notwithstanding any other clause in this contract, disputes relative to this clause will be governed by the procedures in 41 CFR part 60-1.

I.62     FAR 52.222-35, Equal Opportunity for Veterans (OCT 2015)

(a)     Definitions. As used in this clause— 
“Active duty wartime or campaign badge veteran,” “Armed Forces service medal veteran,” “disabled veteran,” “protected veteran,” “qualified disabled veteran,” and “recently separated veteran” have the meanings given at FAR 22.1301. 
		
	(b) 
	Equal opportunity clause. The Contractor shall abide by the requirements of the equal opportunity clause at 41 CFR 60-300.5(a), as of March 24, 2014. This clause prohibits discrimination against qualified protected veterans, and requires affirmative action by the Contractor to employ and advance in employment qualified protected veterans.

		
	(c) 
	Subcontracts. The Contractor shall insert the terms of this clause in subcontracts of $150,000 or more unless exempted by rules, regulations, or orders of the Secretary of Labor. The Contractor shall act as specified by the Director, Office of Federal Contract Compliance Programs, to enforce the terms, including action for noncompliance. Such necessary changes in language may be made as shall be appropriate to identify properly the parties and their undertakings.

I.63     FAR 52.222-36, Equal Opportunity for Workers with Disabilities (JUL 2014)

		
	(a) 
	Equal opportunity clause. The Contractor shall abide by the requirements of the equal opportunity clause at 41 CFR 60-741.5(a), as of March 24, 2014. This clause prohibits discrimination against qualified individuals on the basis of disability, and requires affirmative action by the Contractor to employ and advance in employment qualified individuals with disabilities.

		
	(b)
	 Subcontracts. The Contractor shall include the terms of this clause in every subcontract or purchase order in excess of $15,000 unless exempted by rules, regulations, or orders of the Secretary, so that such provisions will be binding upon each subcontractor or vendor. The Contractor shall act as specified by the Director, Office of Federal Contract Compliance Programs of the U.S. Department of Labor, to enforce the terms, including action for noncompliance. Such necessary changes in language may be made as shall be appropriate to identify properly the parties and their undertakings

I.64  52.222-37 -- Employment Reports on Veterans (Feb 2016)
(a) Definitions. As used in this clause, “active duty wartime or campaign badge veteran,” “Armed Forces service medal veteran,” “disabled veteran,” “protected veteran,” and “recently separated veteran,” have the meanings given in FAR 22.1301.
(b) Unless the Contractor is a State or local government agency, the Contractor shall report at least annually, as required by the Secretary of Labor, on--
(1) The total number of employees in the contractor's workforce, by job category and hiring location, who are protected veterans (i.e., active duty wartime or campaign badge veterans, Armed Forces service medal veterans, disabled veterans, and recently separated veterans);
(2) The total number of new employees hired during the period covered by the report, and of the total, the number of protected veterans (i.e., active duty wartime or campaign badge veterans, Armed Forces service medal veterans, disabled veterans, and recently separated veterans); and
(3) The maximum number and minimum number of employees of the Contractor or subcontractor at each hiring location during the period covered by the report.
(c) The Contractor shall report the above items by filing the VETS-4212 “Federal Contractor Veterans’ Employment Report” (see “VETS-4212 Federal Contractor Reporting” and “Filing Your VETS-4212 Report” at http://www.dol.gov/vets/vets4212.htm ).
(d) The Contractor shall file VETS-4212 Reports no later than September 30 of each year.
(e) The employment activity report required by paragraphs (b)(2) and (b)(3) of this clause shall reflect total new hires, and maximum and minimum number of employees, during the most recent 12-month period preceding the ending date selected for the report. Contractors may select an ending date--
(1) As of the end of any pay period between July 1 and August 31 of the year the report is due; or
(2) As of December 31, if the Contractor has prior written approval from the Equal Employment Opportunity Commission to do so for purposes of submitting the Employer Information Report EEO-1 (Standard Form 100).
(f) The number of veterans reported must be based on data known to the contractor when completing the VETS-4212. The contractor's knowledge of veterans status may be obtained in a variety of ways, including an invitation to applicants to self-identify (in accordance with 41 CFR 60-300.42), voluntary self-disclosure by employees, or actual knowledge of veteran status by the contractor. This paragraph does not relieve an employer of liability for discrimination under 38 U.S.C. 4212.
(g) The Contractor shall insert the terms of this clause in subcontracts of $150,000 or more unless exempted by rules, regulations, or orders of the Secretary of Labor.

I.65  52.222-40 – Notification of Employee Rights Under the National Labor Relations Act (Dec 2010)
(a) During the term of this contract, the Contractor shall post an employee notice, of such size and in such form, and containing such content as prescribed by the Secretary of Labor, in conspicuous places in and about its plants and offices where employees covered by the national Labor Relations Act engage in activities relating to the performance of the contract, including all places where notices to employees are customarily posted both physically and electronically, in the languages employees speak, in accordance with 29 CFR 471.2(d) and (f).
(1) Physical posting of the employee notice shall be in conspicuous places in and about the Contractor’s plants and offices so that the notice is prominent and readily seen by employees who are covered by the National Labor Relations Act and engage in activities related to the performance of the contact.
(2) If the Contractor customarily posts notices to employees electronically, then the Contractor shall also post the required notice electronically by displaying prominently, on any Web site that is maintained by the Contractor and is customarily used for notices to employees about terms and conditions of employment, a link to the Department of Labor’s Web site that contains the full text of the poster. The link to the Department’s Web site, as referenced in (b)(3) of this section, must read, “Important Notice about Employee Rights to Organize and Bargain Collectively with Their Employers.”
(b) This required employee notice, printed by the Department of Labor, may be—
(1) Obtained from the Division of Interpretations and Standards, Office of Labor-Management Standards, U.S. Department of Labor, 200 Constitution Avenue, NW., Room N-5609, Washington, DC 20210, (202) 693-0123, or from any field office of the Office of Labor-Management Standards or Office of Federal Contract Compliance Programs;
(2) Provided by the Federal contracting agency if requested;
(3) Downloaded from the Office of Labor-management Standards Web site at http://www.dol.gov/olms/regs/compliance/EO13496.htm ; or 
(4) Reproduced and used as exact duplicate copies of the Department of Labor’s official poster.
(c) The required text of the employee notice referred to in this clause is located at Appendix A, Subpart A, 29 CFR Part 471.
(d) The Contractor shall comply with all provisions of the employee notice and related rules, regulations, and orders of the Secretary of Labor.
(e) In the event that the Contractor does not comply with the requirements set forth in paragraphs (a) through (d) of this clause, this contract may be terminated or suspended in whole or in part, and the Contractor may be suspended or debarred in accordance with 29 CFR 471.14 and subpart 9.4 Such other sanctions or remedies may be imposed as are provided by 29 CFR part 471, which implements Executive Order 13496 or as otherwise provided by law.
(f) Subcontracts.
(1) The Contractor shall include the substance of this clause, including this paragraph (f), in every subcontract that exceeds $10,000 and will be performed wholly or partially in the Unites States, unless exempted by the rules, regulations, or orders of the Secretary of Labor issued pursuant to section 3 of Executive Order 13496 of January 30, 2009, so that such provisions will be binding upon each subcontractor.
(2) The Contractor shall not procure supplies or services in a way designed to avoid the applicability of Executive Order 13496 or this clause.
(3) The Contractor shall take such action with respect to any such subcontract as may be directed by the Secretary of Labor as a means of enforcing such provisions, including the imposition of sanctions for noncompliance.
(4) However, if the Contractor becomes involved in litigation with a subcontractor, or is threatened with such involvement, as a result of such direction, the Contractor may request the United States, through the Secretary of Labor, to enter into such litigation to protect the interests of the United States.

I.66  52.222-41 -- Service Contract Labor Standards (Aug 2018)
(a) Definitions. As used in this clause—
“Contractor” when this clause is used in any subcontract, shall be deemed to refer to the subcontractor, except in the term “Government Prime Contractor.”
“Service employee” means any person engaged in the performance of this contract other than any person employed in a bona fide executive, administrative, or professional capacity, as these terms are defined in Part 541 of Title 29, Code of Federal Regulations, as revised. It includes all such persons regardless of any contractual relationship that may be alleged to exist between a Contractor or subcontractor and such persons.
(b) Applicability. This contract is subject to the following provisions and to all other applicable provisions of 41 U.S.C. chapter 67, Service Contract Labor Standards, and regulations of the Secretary of Labor (29 CFR Part 4). This clause does not apply to contracts or subcontracts administratively exempted by the Secretary of Labor or exempted by 41 U.S.C. 6702, as interpreted in Subpart C of 29 CFR Part 4.
(c) Compensation.
(1) Each service employee employed in the performance of this contract by the Contractor or any subcontractor shall be paid not less than the minimum monetary wages and shall be furnished fringe benefits in accordance with the wages and fringe benefits determined by the Secretary of Labor, or authorized representative, as specified in any wage determination attached to this contract.
(2)
(i) If a wage determination is attached to this contract, the Contractor shall classify any class of service employee which is not listed therein and which is to be employed under the contract (i.e., the work to be performed is not performed by any classification listed in the wage determination) so as to provide a reasonable relationship (i.e., appropriate level of skill comparison) between such unlisted classifications and the classifications listed in the wage determination. Such conformed class of employees shall be paid the monetary wages and furnished the fringe benefits as are determined pursuant to the procedures in this paragraph (c).
(ii) This conforming procedure shall be initiated by the Contractor prior to the performance of contract work by the unlisted class of employee. The Contractor shall submit Standard Form (SF) 1444, Request For Authorization of Additional Classification and Rate, to the Contracting Officer no later than 30 days after the unlisted class of employee performs any contract work. The Contracting Officer shall review the proposed classification and rate and promptly submit the completed SF 1444 (which must include information regarding the agreement or disagreement of the employees’ authorized representatives or the employees themselves together with the agency recommendation), and all pertinent information to the Wage and Hour Division, U.S. Department of Labor. The Wage and Hour Division will approve, modify, or disapprove the action or render a final determination in the event of disagreement within 30 days of receipt or will notify the Contracting Officer within 30 days of receipt that additional time is necessary.
(iii) The final determination of the conformance action by the Wage and Hour Division shall be transmitted to the Contracting Officer who shall promptly notify the Contractor of the action taken. Each affected employee shall be furnished by the Contractor with a written copy of such determination or it shall be posted as a part of the wage determination.
(iv)
(A) The process of establishing wage and fringe benefit rates that bear a reasonable relationship to those listed in a wage determination cannot be reduced to any single formula. The approach used may vary from wage determination to wage determination depending on the circumstances. Standard wage and salary administration practices which rank various job classifications by pay grade pursuant to point schemes or other job factors may, for example, be relied upon. Guidance may also be obtained from the way different jobs are rated under Federal pay systems (Federal Wage Board Pay System and the General Schedule) or from other wage determinations issued in the same locality. Basic to the establishment of any conformable wage rate(s) is the concept that a pay relationship should be maintained between job classifications based on the skill required and the duties performed.
(B) In the case of a contract modification, an exercise of an option, or extension of an existing contract, or in any other case where a Contractor succeeds a contract under which the classification in question was previously conformed pursuant to paragraph (c) of this clause, a new conformed wage rate and fringe benefits may be assigned to the conformed classification by indexing (i.e., adjusting) the previous conformed rate and fringe benefits by an amount equal to the average (mean) percentage increase (or decrease, where appropriate) between the wages and fringe benefits specified for all classifications to be used on the contract which are listed in the current wage determination, and those specified for the corresponding classifications in the previously applicable wage determination. Where conforming actions are accomplished in accordance with this paragraph prior to the performance of contract work by the unlisted class of employees, the Contractor shall advise the Contracting Officer of the action taken but the other procedures in subdivision (c)(2)(ii) of this clause need not be followed.
(C) No employee engaged in performing work on this contract shall in any event be paid less than the currently applicable minimum wage specified under section 6(a)(1) of the Fair Labor Standards Act of 1938, as amended.
(v) The wage rate and fringe benefits finally determined under this subparagraph (c)(2) of this clause shall be paid to all employees performing in the classification from the first day on which contract work is performed by them in the classification. Failure to pay the unlisted employees the compensation agreed upon by the interested parties and/or finally determined by the Wage and Hour Division retroactive to the date such class of employees commenced contract work shall be a violation of the Service Contract Labor Standards statute and this contract.
(vi) Upon discovery of failure to comply with subparagraph (c)(2) of this clause, the Wage and Hour Division shall make a final determination of conformed classification, wage rate, and/or fringe benefits which shall be retroactive to the date such class or classes of employees commenced contract work.
(3) Adjustment of compensation. If the term of this contract is more than 1 year, the minimum monetary wages and fringe benefits required to be paid or furnished thereunder to service employees under this contract shall be subject to adjustment after 1 year and not less often than once every 2 years, under wage determinations issued by the Wage and Hour Division.
(d) Obligation to furnish fringe benefits. The Contractor or subcontractor may discharge the obligation to furnish fringe benefits specified in the attachment or determined under subparagraph (c)(2) of this clause by furnishing equivalent combinations of bona fide fringe benefits, or by making equivalent or differential cash payments, only in accordance with Subpart D of 29 CFR Part 4.
(e) Minimum wage. In the absence of a minimum wage attachment for this contract, neither the Contractor nor any subcontractor under this contract shall pay any person performing work under this contract (regardless of whether the person is a service employee) less than the minimum wage specified by section 6(a)(1) of the Fair Labor Standards Act of 1938. Nothing in this clause shall relieve the Contractor or any subcontractor of any other obligation under law or contract for payment of a higher wage to any employee.
(f) Successor contracts. If this contract succeeds a contract subject to the Service Contract Labor Standards statute under which substantially the same services were furnished in the same locality and service employees were paid wages and fringe benefits provided for in a collective bargaining agreement, in the absence of the minimum wage attachment for this contract setting forth such collectively bargained wage rates and fringe benefits, neither the Contractor nor any subcontractor under this contract shall pay any service employee performing any of the contract work (regardless of whether or not such employee was employed under the predecessor contract), less than the wages and fringe benefits provided for in such collective bargaining agreement, to which such employee would have been entitled if employed under the predecessor contract, including accrued wages and fringe benefits and any prospective increases in wages and fringe benefits provided for under such agreement. No Contractor or subcontractor under this contract may be relieved of the foregoing obligation unless the limitations of 29 CFR 4.1b(b) apply or unless the Secretary of Labor or the Secretary’s authorized representative finds, after a hearing as provided in 29 CFR 4.10 that the wages and/or fringe benefits provided for in such agreement are substantially at variance with those which prevail for services of a character similar in the locality, or determines, as provided in 29 CFR 4.11, that the collective bargaining agreement applicable to service employees employed under the predecessor contract was not entered into as a result of arm’s length negotiations. Where it is found in accordance with the review procedures provided in 29 CFR 4.10 and/or 4.11 and Parts 6 and 8 that some or all of the wages and/or fringe benefits contained in a predecessor Contractor’s collective bargaining agreement are substantially at variance with those which prevail for services of a character similar in the locality, and/or that the collective bargaining agreement applicable to service employees employed under the predecessor contract was not entered into as a result of arm’s length negotiations, the Department will issue a new or revised wage determination setting forth the applicable wage rates and fringe benefits. Such determination shall be made part of the contract or subcontract, in accordance with the decision of the Administrator, the Administrative Law Judge, or the Administrative Review Board, as the case may be, irrespective of whether such issuance occurs prior to or after the award of a contract or subcontract (53 Comp. Gen. 401 (1973)). In the case of a wage determination issued solely as a result of a finding of substantial variance, such determination shall be effective as of the date of the final administrative decision.
(g) Notification to employees. The Contractor and any subcontractor under this contract shall notify each service employee commencing work on this contract of the minimum monetary wage and any fringe benefits required to be paid pursuant to this contract, or shall post the wage determination attached to this contract. The poster provided by the Department of Labor (Publication WH 1313) shall be posted in a prominent and accessible place at the worksite. Failure to comply with this requirement is a violation of 41 U.S.C. 6703 and of this contract.
(h) Safe and sanitary working conditions. The Contractor or subcontractor shall not permit any part of the services called for by this contract to be performed in buildings or surroundings or under working conditions provided by or under the control or supervision of the Contractor or subcontractor which are unsanitary, hazardous, or dangerous to the health or safety of the service employees. The Contractor or subcontractor shall comply with the safety and health standards applied under 29 CFR Part 1925.
(i) Records.
(1) The Contractor and each subcontractor performing work subject to the Service Contract Labor Standards statute shall make and maintain for 3 years from the completion of the work, and make them available for inspection and transcription by authorized representatives of the Wage and Hour Division, a record of the following:
(i) For each employee subject to the Service Contract Labor Standards statute--
(A) Name and address and social security number;
(B) Correct work classification or classifications, rate or rates of monetary wages paid and fringe benefits provided, rate or rates of payments in lieu of fringe benefits, and total daily and weekly compensation;
(C) Daily and weekly hours worked by each employee; and
(D) Any deductions, rebates, or refunds from the total daily or weekly compensation of each employee.
(ii) For those classes of service employees not included in any wage determination attached to this contract, wage rates or fringe benefits determined by the interested parties or by the Administrator or authorized representative under the terms of paragraph (c) of this clause. A copy of the report required by subdivision (c)(2)(ii) of this clause will fulfill this requirement.
(iii) Any list of the predecessor Contractor’s employees which had been furnished to the Contractor as prescribed by paragraph (n) of this clause.
(2) The Contractor shall also make available a copy of this contract for inspection or transcription by authorized representatives of the Wage and Hour Division.
(3) Failure to make and maintain or to make available these records for inspection and transcription shall be a violation of the regulations and this contract, and in the case of failure to produce these records, the Contracting Officer, upon direction of the Department of Labor and notification to the Contractor, shall take action to cause suspension of any further payment or advance of funds until the violation ceases.
(4) The Contractor shall permit authorized representatives of the Wage and Hour Division to conduct interviews with employees at the worksite during normal working hours.
(j) Pay periods. The Contractor shall unconditionally pay to each employee subject to the Service Contract Labor Standards statute all wages due free and clear and without subsequent deduction (except as otherwise provided by law or regulations, 29 CFR Part 4), rebate, or kickback on any account. These payments shall be made no later than one pay period following the end of the regular pay period in which the wages were earned or accrued. A pay period under this statute may not be of any duration longer than semi-monthly.
(k) Withholding of payments and termination of contract. The Contracting Officer shall withhold or cause to be withheld from the Government Prime Contractor under this or any other Government contract with the Prime Contractor such sums as an appropriate official of the Department of Labor requests or such sums as the Contracting Officer decides may be necessary to pay underpaid employees employed by the Contractor or subcontractor. In the event of failure to pay any employees subject to the Service Contract Labor Standards statute all or part of the wages or fringe benefits due under the Service Contract Labor Standards statute, the Contracting Officer may, after authorization or by direction of the Department of Labor and written notification to the Contractor, take action to cause suspension of any further payment or advance of funds until such violations have ceased. Additionally, any failure to comply with the requirements of this clause may be grounds for termination of the right to proceed with the contract work. In such event, the Government may enter into other contracts or arrangements for completion of the work, charging the Contractor in default with any additional cost.
(l) Subcontracts. The Contractor agrees to insert this clause in all subcontracts subject to the Service Contract Labor Standards statute.
(m) Collective bargaining agreements applicable to service employees. If wages to be paid or fringe benefits to be furnished any service employees employed by the Government Prime Contractor or any subcontractor under the contract are provided for in a collective bargaining agreement which is or will be effective during any period in which the contract is being performed, the Government Prime Contractor shall report such fact to the Contracting Officer, together with full information as to the application and accrual of such wages and fringe benefits, including any prospective increases, to service employees engaged in work on the contract, and a copy of the collective bargaining agreement. Such report shall be made upon commencing performance of the contract, in the case of collective bargaining agreements effective at such time, and in the case of such agreements or provisions or amendments thereof effective at a later time during the period of contract performance such agreements shall be reported promptly after negotiation thereof.
(n) Seniority list. Not less than 10 days prior to completion of any contract being performed at a Federal facility where service employees may be retained in the performance of the succeeding contract and subject to a wage determination which contains vacation or other benefit provisions based upon length of service with a Contractor (predecessor) or successor (29 CFR 4.173), the incumbent Prime Contractor shall furnish the Contracting Officer a certified list of the names of all service employees on the Contractor’s or subcontractor’s payroll during the last month of contract performance. Such list shall also contain anniversary dates of employment on the contract either with the current or predecessor Contractors of each such service employee. The Contracting Officer shall turn over such list to the successor Contractor at the commencement of the succeeding contract.
(o) Rulings and interpretations. Rulings and interpretations of the Service Contract Labor Standards statute are contained in Regulations, 29 CFR Part 4.
(p) Contractor’s certification.
(1) By entering into this contract, the Contractor (and officials thereof) certifies that neither it nor any person or firm who has a substantial interest in the Contractor’s firm is a person or firm ineligible to be awarded Government contracts by virtue of the sanctions imposed under 41 U.S.C. 6706.
(2) No part of this contract shall be subcontracted to any person or firm ineligible for award of a Government contract under 41 U.S.C. 6706.
(3) The penalty for making false statements is prescribed in the U.S. Criminal Code, 18 U.S.C. 1001.
(q) Variations, tolerances, and exemptions involving employment. Notwithstanding any of the provisions in paragraphs (b) through (o) of this clause, the following employees may be employed in accordance with the following variations, tolerances, and exemptions, which the Secretary of Labor, pursuant to 41 U.S.C. 6707 prior to its amendment by Pub.L.92-473, found to be necessary and proper in the public interest or to avoid serious impairment of the conduct of Government business:
(1) Apprentices, student-learners, and workers whose earning capacity is impaired by age, physical or mental deficiency, or injury may be employed at wages lower than the minimum wage otherwise required by 41 U.S.C. 6703(1) without diminishing any fringe benefits or cash payments in lieu thereof required under section 41 U.S.C. 6703(2), in accordance with the conditions and procedures prescribed for the employment of apprentices, student-learners, persons with disabilities, and disabled clients of work centers under section 14 of the Fair Labor Standards Act of 1938, in the regulations issued by the Administrator (29 CFR Parts 520, 521, 524, and 525).
(2) The Administrator will issue certificates under the statute for the employment of apprentices, student-learners, persons with disabilities, or disabled clients of work centers not subject to the Fair Labor Standards Act of 1938, or subject to different minimum rates of pay under the two statutes, authorizing appropriate rates of minimum wages (but without changing requirements concerning fringe benefits or supplementary cash payments in lieu thereof), applying procedures prescribed by the applicable regulations issued under the Fair Labor Standards Act of 1938 (29 CFR Parts 520, 521, 524, and 525).
(3) The Administrator will also withdraw, annul, or cancel such certificates in accordance with the regulations in 29 CFR Parts 525 and 528.
(r) Apprentices. Apprentices will be permitted to work at less than the predetermined rate for the work they perform when they are employed and individually registered in a bona fide apprenticeship program registered with a State Apprenticeship Agency which is recognized by the U.S. Department of Labor, or if no such recognized agency exists in a State, under a program registered with the Office of Apprenticeship Training, Employer, and Labor Services (OATELS), U.S. Department of Labor. Any employee who is not registered as an apprentice in an approved program shall be paid the wage rate and fringe benefits contained in the applicable wage determination for the journeyman classification of work actually performed. The wage rates paid apprentices shall not be less than the wage rate for their level of progress set forth in the registered program, expressed as the appropriate percentage of the journeyman’s rate contained in the applicable wage determination. The allowable ratio of apprentices to journeymen employed on the contract work in any craft classification shall not be greater than the ratio permitted to the Contractor as to his entire work force under the registered program.
(s) Tips. An employee engaged in an occupation in which the employee customarily and regularly receives more than $30 a month in tips may have the amount of these tips credited by the employer against the minimum wage required by 41 U.S.C. 6703(1), in accordance with section 3(m) of the Fair Labor Standards Act and Regulations, 29 CFR Part 531. However, the amount of credit shall not exceed $1.34 per hour beginning January 1, 1981. To use this provision --
(1) The employer must inform tipped employees about this tip credit allowance before the credit is utilized;
(2) The employees must be allowed to retain all tips (individually or through a pooling arrangement and regardless of whether the employer elects to take a credit for tips received);
(3) The employer must be able to show by records that the employee receives at least the applicable Service Contract Labor Standards minimum wage through the combination of direct wages and tip credit; and
(4) The use of such tip credit must have been permitted under any predecessor collective bargaining agreement applicable by virtue of 41 U.S.C. 6707(c).
(t) Disputes concerning labor standards. The U.S. Department of Labor has set forth in 29 CFR Parts 4, 6, and 8 procedures for resolving disputes concerning labor standards requirements. Such disputes shall be resolved in accordance with those procedures and not the Disputes clause of this contract. Disputes within the meaning of this clause include disputes between the Contractor (or any of its subcontractors) and the contracting agency, the U.S. Department of Labor, or the employees or their representatives.

I.67    FAR 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) 
In compliance with the Service Contract Labor Standards statute and the regulations of the Secretary of Labor (29 CFR part 4), this clause identifies the classes of service employees expected to be employed under the contract and states the wages and fringe benefits payable to each if they were employed by the contracting agency subject to the provisions of 5 U.S.C. 5341 or 5332. 
This Statement is for Information Only:   
It is not a Wage Determination.
	
			
	Classifications
	Grade
	Equivalent Pay

	Administrative Assistant
	GS-7
	19.89

	Carpenter
	WG-9
	24.33

	Computer Operator
	GS-6
	17.90

	Electrician
	WG-10
	24.68

	Engineering Technician
	GS-9
	24.33

	Environmental Technician
	GS-7
	19.89

	Forklift Operator
	WG-5
	18.48

	Heavy Equipment Operator
	WG-10
	24.68

	Instrument Mechanic
	WG-10
	24.68

	Janitor
	WG-2
	14.16

	Laborer
	WG-2
	14.16

	Motor Vehicle Operator
	WG-7
	20.91

	Painter
	WG-9
	23.42

	Pipefitter
	WG-10
	24.68

	Receiving Clerk
	WG-4
	17.12

	Secretary
	GS-6
	17.90

	Technical Writer
	GS-9
	24.33

	Truck Driver
	WG-8
	22.27

	Welder
	WG-10
	24.68

The fringe benefit rate is $4.41/hour which is in addition to the above hourly rates.

I.68  52.222-43 -- Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (Multiple Year and Option Contracts (Aug 2018)
(a) This clause applies to both contracts subject to area prevailing wage determinations and contracts subject to collective bargaining agreements.
(b) The Contractor warrants that the prices in this contract do not include any allowance for any contingency to cover increased costs for which adjustment is provided under this clause.
(c) The wage determination, issued under the Service Contract Labor Standards statute, (41 U.S.C. chapter 67), by the Administrator, Wage and Hour Division, U.S. Department of Labor, current on the anniversary date of a multiple year contract or the beginning of each renewal option period, shall apply to this contract. If no such determination has been made applicable to this contract, then the Federal minimum wage as established by section 6(a)(1) of the Fair Labor Standards Act of 1938, as amended, (29 U.S.C. 206) current on the anniversary date of a multiple year contract or the beginning of each renewal option period, shall apply to this contract.
(d) The contract price, contract unit price labor rates, or fixed hourly labor rates will be adjusted to reflect the Contractor’s actual increase or decrease in applicable wages and fringe benefits to the extent that the increase is made to comply with or the decrease is voluntarily made by the Contractor as a result of:
(1) The Department of Labor wage determination applicable on the anniversary date of the multiple year contract, or at the beginning of the renewal option period. For example, the prior year wage determination required a minimum wage rate of $4.00 per hour. The Contractor chose to pay $4.10. The new wage determination increases the minimum rate to $4.50 per hour. Even if the Contractor voluntarily increases the rate to $4.75 per hour, the allowable price adjustment is $.40 per hour;
(2) An increased or decreased wage determination otherwise applied to the contract by operation of law; or
(3) An amendment to the Fair Labor Standards Act of 1938 that is enacted after award of this contract, affects the minimum wage, and becomes applicable to this contract under law.
(e) Any adjustment will be limited to increases or decreases in wages and fringe benefits as described in paragraph (d) of this clause, and the accompanying increases or decreases in social security and unemployment taxes and workers’ compensation insurance, but shall not otherwise include any amount for general and administrative costs, overhead, or profit.
(f) The Contractor shall notify the Contracting Officer of any increase claimed under this clause within 30 days after receiving a new wage determination unless this notification period is extended in writing by the Contracting Officer. The Contractor shall promptly notify the Contracting Officer of any decrease under this clause, but nothing in the clause shall preclude the Government from asserting a claim within the period permitted by law. The notice shall contain a statement of the amount claimed and the change in fixed hourly rates (if this is a time-and-materials or labor-hour contract), and any relevant supporting data, including payroll records, that the Contracting Officer may reasonably require. Upon agreement of the parties, the contract price, contract unit price labor rates, or fixed hourly rates shall be modified in writing. The Contractor shall continue performance pending agreement on or determination of any such adjustment and its effective date.
(g) The Contracting Officer or an authorized representative shall have access to and the right to examine any directly pertinent books, documents, papers and records of the Contractor until the expiration of 3 years after final payment under the contract.

I.69  52.222-50 -- Combating Trafficking in Persons (Jan 2019)
(a) Definitions. As used in this clause—
“Agent” means any individual, including a director, an officer, an employee, or an independent contractor, authorized to act on behalf of the organization.
“Coercion” means—
(1) Threats of serious harm to or physical restraint against any person;
(2) Any scheme, plan, or pattern intended to cause a person to believe that failure to perform an act would result in serious harm to or physical restraint against any person; or
(3) The abuse or threatened abuse of the legal process.
“Commercial sex act” means any sex act on account of which anything of value is given to or received by any person.
“Commercially available off-the-shelf (COTS) item” means--
(1) Any item of supply (including construction material) that is—
(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);
(ii) Sold in substantial quantities in the commercial marketplace; and
(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and
(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.
“Debt bondage” means the status or condition of a debtor arising from a pledge by the debtor of his or her personal services or of those of a person under his or her control as a security for debt, if the value of those services as reasonably assessed is not applied toward the liquidation of the debt or the length and nature of those services are not respectively limited and defined.
“Employee” means an employee of the Contractor directly engaged in the performance of work under the contract who has other than a minimal impact or involvement in contract performance.
“Forced labor” means knowingly providing or obtaining the labor or services of a person—
(1) By threats of serious harm to, or physical restraint against, that person or another person;
(2) By means of any scheme, plan, or pattern intended to cause the person to believe that, if the person did not perform such labor or services, that person or another person would suffer serious harm or physical restraint; or
(3) By means of the abuse or threatened abuse of law or the legal process.
“Involuntary servitude” includes a condition of servitude induced by means of—
(1) Any scheme, plan, or pattern intended to cause a person to believe that, if the person did not enter into or continue in such conditions, that person or another person would suffer serious harm or physical restraint; or
(2) The abuse or threatened abuse of the legal process.
“Recruitment fees” means- Fees of any type, including charges, costs, assessments, or other financial obligations, that are associated with the recruiting process, regardless of the time, manner, or location of imposition or collection of the fee.
(1) Recruitment fees include, but are not limited to, the following fees (when they are associated with the recruiting process) for--
(i) Soliciting, identifying, considering, interviewing, referring, retaining, transferring, selecting, training, providing orientation to, skills testing, recommending, or placing employees or potential employees;
(ii) Advertising;
(iii) Obtaining permanent or temporary labor certification, including any associated fees;
(iv) Processing applications and petitions;
(v) Acquiring visas, including any associated fees;
(vi) Acquiring photographs and identity or immigration documents, 
such as passports, including any associated fees;
(vii) Accessing the job opportunity, including required medical examinations and immunizations; background, reference, and security clearance checks and examinations; and additional certifications;
(viii) An employer's recruiters, agents or attorneys, or other 
notary or legal fees;
(ix) Language interpretation or translation, arranging for or accompanying on travel, or providing other advice to employees or potential employees;
(x) Government-mandated fees, such as border crossing fees, levies, or worker welfare funds;
(xi) Transportation and subsistence costs--
(A) While in transit, including, but not limited to, airfare or costs of other modes of transportation, terminal fees, and travel taxes associated with travel from the country of origin to the country of performance and the return journey upon the end of employment; and
(B) From the airport or disembarkation point to the worksite;
(xii) Security deposits, bonds, and insurance; and
(xiii) Equipment charges.
(2) A recruitment fee, as described in the introductory text of this definition, is a recruitment fee, regardless of whether the payment is--
(i) Paid in property or money;
(ii) Deducted from wages;
(iii) Paid back in wage or benefit concessions;
(iv) Paid back as a kickback, bribe, in-kind payment, free labor, tip, or tribute; or
(v) Collected by an employer or a third party, whether licensed or unlicensed, including, but not limited to--
(A) Agents;
(B) Labor brokers;
(C) Recruiters;
(D) Staffing firms (including private employment and placement firms);
(E) Subsidiaries/affiliates of the employer;
(F) Any agent or employee of such entities; and
(G) Subcontractors at all tiers.
“Severe forms of trafficking in persons” means—
(1) Sex trafficking in which a commercial sex act is induced by force, fraud, or coercion, or in which the person induced to perform such act has not attained 18 years of age; or
(2) The recruitment, harboring, transportation, provision, or obtaining of a person for labor or services, through the use of force, fraud, or coercion for the purpose of subjection to involuntary servitude, peonage, debt bondage, or slavery.
“Sex trafficking” means the recruitment, harboring, transportation, provision, or obtaining of a person for the purpose of a commercial sex act.
“Subcontract” means any contract entered into by a subcontractor to furnish supplies or services for performance of a prime contract or a subcontract.
“Subcontractor” means any supplier, distributor, vendor, or firm that furnishes supplies or services to or for a prime contractor or another subcontractor.
“United States” means the 50 States, the District of Columbia, and outlying areas.
(b) Policy. The United States Government has adopted a policy prohibiting trafficking in persons including the trafficking-related activities of this clause. Contractors, contractor employees, and their agents shall not—
(1) Engage in severe forms of trafficking in persons during the period of performance of the contract;
(2) Procure commercial sex acts during the period of performance of the contract;
(3) Use forced labor in the performance of the contract;
(4) Destroy, conceal, confiscate, or otherwise deny access by an employee to the employee's identity or immigration documents, such as passports or drivers' licenses, regardless of issuing authority;
(5)
(i) Use misleading or fraudulent practices during the recruitment of employees or offering of employment, such as failing to disclose, in a format and language understood by the employee or potential employee, basic information or making material misrepresentations during the recruitment of employees regarding the key terms and conditions of employment, including wages and fringe benefits, the location of work, the living conditions, housing and associated costs (if employer or agent provided or arranged), any significant costs to be charged to the employee or potential employee, and, if applicable, the hazardous nature of the work;
(ii) Use recruiters that do not comply with local labor laws of the country in which the recruiting takes place;
(6) Charge employees or potential employees recruitment fees;
(7)
(i) Fail to provide return transportation or pay for the cost of return transportation upon the end of employment--
(A) For an employee who is not a national of the country in which the work is taking place and who was brought into that country for the purpose of working on a U.S. Government contract or subcontract (for portions of contracts performed outside the United States); or
(B) For an employee who is not a United States national and who was brought into the United States for the purpose of working on a U.S. Government contract or subcontract, if the payment of such costs is required under existing temporary worker programs or pursuant to a written agreement with the employee (for portions of contracts performed inside the United States); except that--
(ii) The requirements of paragraphs (b)(7)(i) of this clause shall not apply to an employee who is--
(A) Legally permitted to remain in the country of employment and who chooses to do so; or
(B) Exempted by an authorized official of the contracting agency from the requirement to provide return transportation or pay for the cost of return transportation;
(iii) The requirements of paragraph (b)(7)(i) of this clause are modified for a victim of trafficking in persons who is seeking victim services or legal redress in the country of employment, or for a witness in an enforcement action related to trafficking in persons. The contractor shall provide the return transportation or pay the cost of return transportation in a way that does not obstruct the victim services, legal redress, or witness activity. For example, the contractor shall not only offer return transportation to a witness at a time when the witness is still needed to testify. This paragraph does not apply when the exemptions at paragraph (b)(7)(ii) of this clause apply.
(8) Provide or arrange housing that fails to meet the host country housing and safety standards; or
(9) If required by law or contract, fail to provide an employment contract, recruitment agreement, or other required work document in writing. Such written work document shall be in a language the employee understands. If the employee must relocate to perform the work, the work document shall be provided to the employee at least five days prior to the employee relocating. The employee's work document shall include, but is not limited to, details about work description, wages, prohibition on charging recruitment fees, work location(s), living accommodations and associated costs, time off, roundtrip transportation arrangements, grievance process, and the content of applicable laws and regulations that prohibit trafficking in persons.
(c) Contractor requirements. The Contractor shall—
(1) Notify its employees and agents of—
(i) The United States Government's policy prohibiting trafficking in persons, described in paragraph (b) of this clause; and
(ii) The actions that will be taken against employees or agents for violations of this policy. Such actions for employees may include, but are not limited to, removal from the contract, reduction in benefits, or termination of employment; and
(2) Take appropriate action, up to and including termination, against employees, agents, or subcontractors that violate the policy in paragraph (b) of this clause.
(d) Notification. 
(1) The Contractor shall inform the Contracting Officer and the agency Inspector General immediately of—
(i) Any credible information it receives from any source (including host country law enforcement) that alleges a Contractor employee, subcontractor, subcontractor employee, or their agent has engaged in conduct that violates the policy in paragraph (b) of this clause (see also 18 U.S.C. 1351, Fraud in Foreign Labor Contracting, and 52.203-13(b)(3)(i)(A), if that clause is included in the solicitation or contract, which requires disclosure to the agency Office of the Inspector General when the Contractor has credible evidence of fraud); and
(ii) Any actions taken against a Contractor employee, subcontractor, subcontractor employee, or their agent pursuant to this clause.
(2) If the allegation may be associated with more than one contract, the Contractor shall inform the contracting officer for the contract with the highest dollar value.
(e) Remedies. In addition to other remedies available to the Government, the Contractor's failure to comply with the requirements of paragraphs (c), (d), (g), (h), or (i) of this clause may result in—
(1) Requiring the Contractor to remove a Contractor employee or employees from the performance of the contract;
(2) Requiring the Contractor to terminate a subcontract; 
(3) Suspension of contract payments until the Contractor has taken appropriate remedial action; 
(4) Loss of award fee, consistent with the award fee plan, for the performance period in which the Government determined Contractor non-compliance;
(5) Declining to exercise available options under the contract;
(6) Termination of the contract for default or cause, in accordance with the termination clause of this contract; or
(7) Suspension or debarment.
(f) Mitigating and aggravating factors. When determining remedies, the Contracting Officer may consider the following:
(1) Mitigating factors. The Contractor had a Trafficking in Persons compliance plan or an awareness program at the time of the violation, was in compliance with the plan, and has taken appropriate remedial actions for the violation, that may include reparation to victims for such violations.
(2) Aggravating factors. The Contractor failed to abate an alleged violation or enforce the requirements of a compliance plan, when directed by the Contracting Officer to do so.
(g) Full cooperation. 
(1) The Contractor shall, at a minimum—
(i) Disclose to the agency Inspector General information sufficient to identify the nature and extent of an offense and the individuals responsible for the conduct;
(ii) Provide timely and complete responses to Government auditors' and investigators' requests for documents;
(iii) Cooperate fully in providing reasonable access to its facilities and staff (both inside and outside the U.S.) to allow contracting agencies and other responsible Federal agencies to conduct audits, investigations, or other actions to ascertain compliance with the Trafficking Victims Protection Act of 2000 (22 U.S.C. chapter 78), E.O. 13627, or any other applicable law or regulation establishing restrictions on trafficking in persons, the procurement of commercial sex acts, or the use of forced labor; and
(iv) Protect all employees suspected of being victims of or witnesses to prohibited activities, prior to returning to the country from which the employee was recruited, and shall not prevent or hinder the ability of these employees from cooperating fully with Government authorities.
(2) The requirement for full cooperation does not foreclose any Contractor rights arising in law, the FAR, or the terms of the contract. It does not—
(i) Require the Contractor to waive its attorney-client privilege or the protections afforded by the attorney work product doctrine;
(ii) Require any officer, director, owner, employee, or agent of the Contractor, including a sole proprietor, to waive his or her attorney client privilege or Fifth Amendment rights; or
(iii) Restrict the Contractor from—
(A) Conducting an internal investigation; or
(B) Defending a proceeding or dispute arising under the contract or related to a potential or disclosed violation.
(h) Compliance plan. 
(1) This paragraph (h) applies to any portion of the contract that—
(i) Is for supplies, other than commercially available off-the-shelf items, acquired outside the United States, or services to be performed outside the United States; and
(ii) Has an estimated value that exceeds $500,000.
(2) The Contractor shall maintain a compliance plan during the performance of the contract that is appropriate—
(i) To the size and complexity of the contract; and
(ii) To the nature and scope of the activities to be performed for the Government, including the number of non-United States citizens expected to be employed and the risk that the contract or subcontract will involve services or supplies susceptible to trafficking in persons.
(3) Minimum requirements. The compliance plan must include, at a minimum, the following:
(i) An awareness program to inform contractor employees about the Government's policy prohibiting trafficking-related activities described in paragraph (b) of this clause, the activities prohibited, and the actions that will be taken against the employee for violations. Additional information about Trafficking in Persons and examples of awareness programs can be found at the Web site for the Department of State's Office to Monitor and Combat Trafficking in Persons at http://www.state.gov/j/tip/.
(ii) A process for employees to report, without fear of retaliation, activity inconsistent with the policy prohibiting trafficking in persons, including a means to make available to all employees the hotline phone number of the Global Human Trafficking Hotline at 1-844-888-FREE and its email address at help@befree.org.
(iii) A recruitment and wage plan that only permits the use of recruitment companies with trained employees, prohibits charging recruitment fees to the employee or potential employees, and ensures that wages meet applicable host-country legal requirements or explains any variance.
(iv) A housing plan, if the Contractor or subcontractor intends to provide or arrange housing, that ensures that the housing meets host-country housing and safety standards.
(v) Procedures to prevent agents and subcontractors at any tier and at any dollar value from engaging in trafficking in persons (including activities in paragraph (b) of this clause) and to monitor, detect, and terminate any agents, subcontracts, or subcontractor employees that have engaged in such activities.
(4) Posting. 
(i) The Contractor shall post the relevant contents of the compliance plan, no later than the initiation of contract performance, at the workplace (unless the work is to be performed in the field or not in a fixed location) and on the Contractor's Web site (if one is maintained). If posting at the workplace or on the Web site is impracticable, the Contractor shall provide the relevant contents of the compliance plan to each worker in writing.
(ii) The Contractor shall provide the compliance plan to the Contracting Officer upon request.
(5) Certification. Annually after receiving an award, the Contractor shall submit a certification to the Contracting Officer that—
(i) It has implemented a compliance plan to prevent any prohibited activities identified at paragraph (b) of this clause and to monitor, detect, and terminate any agent, subcontract or subcontractor employee engaging in prohibited activities; and
(ii) After having conducted due diligence, either—
(A) To the best of the Contractor's knowledge and belief, neither it nor any of its agents, subcontractors, or their agents is engaged in any such activities; or
(B) If abuses relating to any of the prohibited activities identified in paragraph (b) of this clause have been found, the Contractor or subcontractor has taken the appropriate remedial and referral actions.
(i) Subcontracts. 
(1) The Contractor shall include the substance of this clause, including this paragraph (i), in all subcontracts and in all contracts with agents. The requirements in paragraph (h) of this clause apply only to any portion of the subcontract that—
(A) Is for supplies, other than commercially available off-the-shelf items, acquired outside the United States, or services to be performed outside the United States; and
(B) Has an estimated value that exceeds $500,000.
(2) If any subcontractor is required by this clause to submit a certification, the Contractor shall require submission prior to the award of the subcontract and annually thereafter. The certification shall cover the items in paragraph (h)(5) of this clause.

I.70  52.222-54 – Employment Eligibility Verification (Oct 2015)
(a) Definitions. As used in this clause—
“Commercially available off-the-shelf (COTS) item”—
(1) Means any item of supply that is—
(i) A commercial item (as defined in paragraph (1) of the definition at 2.101);
(ii) Sold in substantial quantities in the commercial marketplace; and
(iii) Offered to the Government, without modification, in the same form in which it is sold in the commercial marketplace; and
(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4) such as agricultural products and petroleum products. Per 46 CFR 525.1(c)(2), “bulk cargo” means cargo that is loaded and carried in bulk onboard ship without mark or count, in a loose unpackaged form, having homogenous characteristics. Bulk cargo loaded into intermodal equipment, except LASH or Seabee barges, is subject to mark and count and, therefore, ceases to be bulk cargo.
“Employee assigned to the contract” means an employee who was hired after November 6, 1986 (after November 27, 2009, in the Commonwealth of the Northern Mariana Islands), who is directly performing work, in the United States, under a contract that is required to include the clause prescribed at 22.1803. An employee is not considered to be directly performing work under a contract if the employee—
(1) Normally performs support work, such as indirect or overhead functions; and
(2) Does not perform any substantial duties applicable to the contract.
“Subcontract” means any contract, as defined in 2.101, entered into by a subcontractor to furnish supplies or services for performance of a prime contract or a subcontract. It includes but is not limited to purchase orders, and changes and modifications to purchase orders.
“Subcontractor” means any supplier, distributor, vendor, or firm that furnishes supplies or services to or for a prime Contractor or another subcontractor.
“United States,” as defined in 8 U.S.C. 1101(a)(38), means the 50 States, the District of Columbia, Puerto Rico, Guam, the Commonwealth of the Northern Mariana Islands, and the U.S. Virgin Islands.
(b) Enrollment and verification requirements.
(1) If the Contractor is not enrolled as a Federal Contractor in E-Verify at time of contract award, the Contractor shall—
(i) Enroll. Enroll as a Federal Contractor in the E-Verify program within 30 calendar days of contract award;
(ii) Verify all new employees. Within 90 calendar days of enrollment in the E-Verify program, begin to use E-Verify to initiate verification of employment eligibility of all new hires of the Contractor, who are working in the United States, whether or not assigned to the contract, within 3 business days after the date of hire (but see paragraph (b)(3) of this section); and
(iii) Verify employees assigned to the contract. For each employee assigned to the contract, initiate verification within 90 calendar days after date of enrollment or within 30 calendar days of the employee’s assignment to the contract, whichever date is later (but see paragraph (b)(4) of this section).
(2) If the Contractor is enrolled as a Federal Contractor in E-Verify at time of contract award, the Contractor shall use E-Verify to initiate verification of employment eligibility of—
(i) All new employees.
(A) Enrolled 90 calendar days or more. The Contractor shall initiate verification of all new hires of the Contractor, who are working in the United States, whether or not assigned to the contract within 3 business days after the date of hire (but see paragraph (b)(3) of this section); or
(B) Enrolled less than 90 calendar days. Within 90 calendar days after enrollment as a Federal Contractor in E-Verify, the Contractor shall initiate verification of all new hires of the Contractor, who are working in the United States, whether or not assigned to the contract, within 3 business days after the date of hire (but see paragraph (b)(3) of this section ); or
(ii) Employees assigned to the contract. For each employee assigned to the contract, the Contractor shall initiate verification within 90 calendar days after date of contract award or within 30 days after assignment to the contract, whichever date is later (but see paragraph (b)(4) of this section).
(3) If the Contractor is an institution of higher education (as defined at 20 U.S.C. 1001(a)); a State or local government or the government of a Federally recognized Indian tribe; or a surety performing under a takeover agreement entered into with a Federal agency pursuant to a performance bond, the Contractor may choose to verify only employees assigned to the contract, whether existing employees or new hires. The Contractor shall follow the applicable verification requirements at (b)(1) or (b)(2), respectively, except that any requirement for verification of new employees applies only to new employees assigned to the contract.
(4) Option to verify employment eligibility of all employees. The Contractor may elect to verify all existing employees hired after November 6, 1986 (after November 27, 2009, in the Commonwealth of the Northern Mariana Islands), rather than just those employees assigned to the contract. The Contractor shall initiate verification for each existing employee working in the United States who was hired after November 6, 1986 (after November 27, 2009, in the Commonwealth of the Northern Mariana Islands), within 180 calendar days of—
(i) Enrollment in the E-Verify program; or
(ii) Notification to E-Verify Operations of the Contractor’s decision to exercise this option, using the contact information provided in the E-Verify program Memorandum of Understanding (MOU).
(5) The Contractor shall comply, for the period of performance of this contract, with the requirement of the E-Verify program MOU.
(i) The Department of Homeland Security (DHS) or the Social Security Administration (SSA) may terminate the Contractor’s MOU and deny access to the E-Verify system in accordance with the terms of the MOU. In such case, the Contractor will be referred to a suspension or debarment official.
(ii) During the period between termination of the MOU and a decision by the suspension or debarment official whether to suspend or debar, the Contractor is excused from its obligations under paragraph (b) of this clause. If the suspension or debarment official determines not to suspend or debar the Contractor, then the Contractor must reenroll in E-Verify.
(c) Web site. Information on registration for and use of the E-Verify program can be obtained via the Internet at the Department of Homeland Security Web site: http://www.dhs.gov/E-Verify .
(d) Individuals previously verified. The Contractor is not required by this clause to perform additional employment verification using E-Verify for any employee—
(1) Whose employment eligibility was previously verified by the Contractor through the E-Verify program;
(2) Who has been granted and holds an active U.S. Government security clearance for access to confidential, secret, or top secret information in accordance with the National Industrial Security Program Operating Manual; or
(3) Who has undergone a completed background investigation and been issued credentials pursuant to Homeland Security Presidential Directive (HSPD) -12, Policy for a Common Identification Standard for Federal Employees and Contractors.
(e) Subcontracts. The contractor shall include the requirements of this clause, including this paragraph (e) (appropriately modified for identification of the parties), in each subcontract that—
(1) Is for—
(i) Commercial or noncommercial services (except for commercial services that are part of the purchase of a COTS item (or an item that would be a COTS item, but for minor modifications), performed by the COTS provider, and are normally provided for that COTS item); or
(ii) Construction;
(2) Has a value of more than $3,500; and
(3) Includes work performed in the United States.

I.71  52.222-55 -- Minimum Wages Under Executive Order 13658 (Dec 2015)
(a) Definitions. As used in this clause--
“United States'' means the 50 states and the District of Columbia.
“Worker''—
(1) Means any person engaged in performing work on, or in connection with, a contract covered by Executive Order 13658, and—
(i) Whose wages under such contract are governed by the Fair Labor Standards Act (29 U.S.C. chapter 8), the Service Contract Labor Standards statute (41 U.S.C. chapter 67), or the Wage Rate Requirements (Construction) statute (40 U.S.C. chapter 31, subchapter IV);
(ii) Other than individuals employed in a bona fide executive, administrative, or professional capacity, as those terms are defined in 29 CFR part 541; and
(iii) Regardless of the contractual relationship alleged to exist between the individual and the employer.
(2) Includes workers performing on, or in connection with, the contract whose wages are calculated pursuant to special certificates issued under 29 U.S.C. 214(c).
(3) Also includes any person working on, or in connection with, the contract and individually registered in a bona fide apprenticeship or training program registered with the Department of Labor's Employment and Training Administration, Office of Apprenticeship, or with a State Apprenticeship Agency recognized by the Office of Apprenticeship.
(b) Executive Order Minimum Wage rate. 
(1) The Contractor shall pay to workers, while performing in the United States, and performing on, or in connection with, this contract, a minimum hourly wage rate of $10.10 per hour beginning January 1, 2015.
(2) The Contractor shall adjust the minimum wage paid, if necessary, beginning January 1, 2016, and annually thereafter, to meet the applicable annual E.O. minimum wage. The Administrator of the Department of Labor's Wage and Hour Division (the Administrator) will publish annual determinations in the Federal Register no later than 90 days before the effective date of the new E.O. minimum wage rate. The Administrator will also publish the applicable E.O. minimum wage on www.wdol.gov (or any successor Web site) and a general notice on all wage determinations issued under the Service Contract Labor Standards statute or the Wage Rate Requirements (Construction) statute, that will provide information on the E.O. minimum wage and how to obtain annual updates. The applicable published E.O. minimum wage is incorporated by reference into this contract.
(3)
(i) The Contractor may request a price adjustment only after the effective date of the new annual E.O. minimum wage determination. Prices will be adjusted only for increased labor costs (including subcontractor labor costs) as a result of an increase in the annual E.O. minimum wage, and for associated labor costs (including those for subcontractors). Associated labor costs shall include increases or decreases that result from changes in social security and unemployment taxes and workers' compensation insurance, but will not otherwise include any amount for general and administrative costs, overhead, or profit.
(ii) Subcontractors may be entitled to adjustments due to the new minimum wage, pursuant to paragraph (b)(2). Contractors shall consider any subcontractor requests for such price adjustment.
(iii) The Contracting Officer will not adjust the contract price under this clause for any costs other than those identified in paragraph (b)(3)(i) of this clause, and will not provide duplicate price adjustments with any price adjustment under clauses implementing the Service Contract Labor Standards statute or the Wage Rate Requirements (Construction) statute.
(4) The Contractor warrants that the prices in this contract do not include allowance for any contingency to cover increased costs for which adjustment is provided under this clause.
(5) A pay period under this clause may not be longer than semi-monthly, but may be shorter to comply with any applicable law or other requirement under this contract establishing a shorter pay period. Workers shall be paid no later than one pay period following the end of the regular pay period in which such wages were earned or accrued.
(6) The Contractor shall pay, unconditionally to each worker, all wages due free and clear without subsequent rebate or kickback. The Contractor may make deductions that reduce a worker's wages below the E.O. minimum wage rate only if done in accordance with 29 CFR 10.23, Deductions.
(7) The Contractor shall not discharge any part of its minimum wage obligation under this clause by furnishing fringe benefits or, with respect to workers whose wages are governed by the Service Contract Labor Standards statute, the cash equivalent thereof.
(8) Nothing in this clause shall excuse the Contractor from compliance with any applicable Federal or State prevailing wage law or any applicable law or municipal ordinance establishing a minimum wage higher than the E.O. minimum wage. However, wage increases under such other laws or municipal ordinances are not subject to price adjustment under this subpart.
(9) The Contractor shall pay the E.O. minimum wage rate whenever it is higher than any applicable collective bargaining agreement(s) wage rate.
(10) The Contractor shall follow the policies and procedures in 29 CFR 10.24(b) and 10.28 for treatment of workers engaged in an occupation in which they customarily and regularly receive more than $30 a month in tips.
(c)
(1) This clause applies to workers as defined in paragraph (a). As provided in that definition--
(i) Workers are covered regardless of the contractual relationship alleged to exist between the contractor or subcontractor and the worker;
(ii) Workers with disabilities whose wages are calculated pursuant to special certificates issued under 29 U.S.C. 214(c) are covered; and
(iii) Workers who are registered in a bona fide apprenticeship program or training program registered with the Department of Labor's Employment and Training Administration, Office of Apprenticeship, or with a State Apprenticeship Agency recognized by the Office of Apprenticeship, are covered.
(2) This clause does not apply to--
(i) Fair Labor Standards Act (FLSA)-covered individuals performing in connection with contracts covered by the E.O., i.e. those individuals who perform duties necessary to the performance of the contract, but who are not directly engaged in performing the specific work called for by the contract, and who spend less than 20 percent of their hours worked in a particular workweek performing in connection with such contracts;
(ii) Individuals exempted from the minimum wage requirements of the FLSA under 29 U.S.C. 213(a) and 214(a) and (b), unless otherwise covered by the Service Contract Labor Standards statute, or the Wage Rate Requirements (Construction) statute. These individuals include but are not limited to--
(A) Learners, apprentices, or messengers whose wages are calculated pursuant to special certificates issued under 29 U.S.C. 214(a).
(B) Students whose wages are calculated pursuant to special certificates issued under 29 U.S.C. 214(b).
(C) Those employed in a bona fide executive, administrative, or professional capacity (29 U.S.C. 213(a)(1) and 29 CFR part 541).
(d) Notice. The Contractor shall notify all workers performing work on, or in connection with, this contract of the applicable E.O. minimum wage rate under this clause. With respect to workers covered by the Service Contract Labor Standards statute or the Wage Rate Requirements (Construction) statute, the Contractor may meet this requirement by posting, in a prominent and accessible place at the worksite, the applicable wage determination under those statutes. With respect to workers whose wages are governed by the FLSA, the Contractor shall post notice, utilizing the poster provided by the Administrator, which can be obtained at www.dol.gov/whd/govcontracts, in a prominent and accessible place at the worksite. Contractors that customarily post notices to workers electronically may post the notice electronically provided the electronic posting is displayed prominently on any Web site that is maintained by the contractor, whether external or internal, and customarily used for notices to workers about terms and conditions of employment.
(e) Payroll Records. 
(1) The Contractor shall make and maintain records, for three years after completion of the work, containing the following information for each worker:
(i) Name, address, and social security number;
(ii) The worker's occupation(s) or classification(s);
(iii) The rate or rates of wages paid;
(iv) The number of daily and weekly hours worked by each worker;
(v) Any deductions made; and
(vi) Total wages paid.
(2) The Contractor shall make records pursuant to paragraph (e)(1) of this clause available for inspection and transcription by authorized representatives of the Administrator. The Contractor shall also make such records available upon request of the Contracting Officer.
(3) The Contractor shall make a copy of the contract available, as applicable, for inspection or transcription by authorized representatives of the Administrator.
(4) Failure to comply with this paragraph (e) shall be a violation of 29 CFR 10.26 and this contract. Upon direction of the Administrator or upon the Contracting Officer's own action, payment shall be withheld until such time as the noncompliance is corrected.
(5) Nothing in this clause limits or otherwise modifies the Contractor's payroll and recordkeeping obligations, if any, under the Service Contract Labor Standards statute, the Wage Rate Requirements (Construction) statute, the Fair Labor Standards Act, or any other applicable law.
(f) Access. The Contractor shall permit authorized representatives of the Administrator to conduct investigations, including interviewing workers at the worksite during normal working hours.
(g) Withholding. The Contracting Officer, upon his or her own action or upon written request of the Administrator, will withhold funds or cause funds to be withheld, from the Contractor under this or any other Federal contract with the same Contractor, sufficient to pay workers the full amount of wages required by this clause.
(h) Disputes. Department of Labor has set forth in 29 CFR 10.51,Disputes concerning contractor compliance, the procedures for resolving disputes concerning a contractor's compliance with Department of Labor regulations at 29 CFR part 10. Such disputes shall be resolved in accordance with those procedures and not the Disputes clause of this contract. These disputes include disputes between the Contractor (or any of its subcontractors) and the contracting agency, the Department of Labor, or the workers or their representatives.
(i) Antiretaliation. The Contractor shall not discharge or in any other manner discriminate against any worker because such worker has filed any complaint or instituted or caused to be instituted any proceeding under or related to compliance with the E.O. or this clause, or has testified or is about to testify in any such proceeding.
(j) Subcontractor compliance. The Contractor is responsible for subcontractor compliance with the requirements of this clause and may be held liable for unpaid wages due subcontractor workers.
(k) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (k) in all subcontracts, regardless of dollar value, that are subject to the Service Contract Labor Standards statute or the Wage Rate Requirements (Construction) statute, and are to be performed in whole or in part in the United States.

I.72  52.222-62 Paid Sick Leave Under Executive Order 13706 (JAN 2017)
(a) Definitions. As used in this clause (in accordance with 29 CFR 13.2)--
“Child, domestic partner, and domestic violence” have the meaning given in 29 CFR 13.2.
“Employee”—
(1)
(i) Means any person engaged in performing work on or in connection with a contract covered by Executive Order (E.O.) 13706; and
(A) Whose wages under such contract are governed by the Service Contract Labor Standards statute (41 U.S.C. chapter 67), the Wage Rate Requirements (Construction) statute (40 U.S.C. chapter 31, subchapter IV), or the Fair Labor Standards Act (29 U.S.C. chapter 8);
(B) Including employees who qualify for an exemption from the Fair Labor Standards Act's minimum wage and overtime provisions;
(C) Regardless of the contractual relationship alleged to exist between the individual and the employer; and
(ii) Includes any person performing work on or in connection with the contract and individually registered in a bona fide apprenticeship or training program registered with the Department of Labor's Employment and Training Administration, Office of Apprenticeship, or with a State Apprenticeship Agency recognized by the Office of Apprenticeship.
(2)
(i) An employee performs ``on'' a contract if the employee directly performs the specific services called for by the contract; and
(ii) An employee performs ``in connection with'' a contract if the employee's work activities are necessary to the performance of a contract but are not the specific services called for by the contract.
“Individual related by blood or affinity whose close association with the employee” is the equivalent of a family relationship has the meaning given in 29 CFR 13.2.
“Multiemployer plan” means a plan to which more than one employer is required to contribute and which is maintained pursuant to one or more collective bargaining agreements between one or more employee organizations and more than one employer.
“Paid sick leave” means compensated absence from employment that is required by E.O. 13706 and 29 CFR part 13.
“Parent, sexual assault, spouse, and stalking” have the meaning given in 29 CFR 13.2.
“United States” means the 50 States and the District of Columbia.
(b) Executive Order 13706. 
(1) This contract is subject to E.O. 13706 and the regulations issued by the Secretary of Labor in 29 CFR part 13 pursuant to the E.O.
(2) If this contract is not performed wholly within the United States, this clause only applies with respect to that part of the contract that is performed within the United States.
(c) Paid sick leave. The Contractor shall--
(1) Permit each employee engaged in performing work on or in connection with this contract to earn not less than 1 hour of paid sick leave for every 30 hours worked;
(2) Allow accrual and use of paid sick leave as required by E.O. 13706 and 29 CFR part 13;
(3) Comply with the accrual, use, and other requirements set forth in 29 CFR 13.5 and 13.6, which are incorporated by reference in this contract;
(4) Provide paid sick leave to all employees when due free and clear and without subsequent deduction (except as otherwise provided by 29 CFR 13.24), rebate, or kickback on any account;
(5) Provide pay and benefits for paid sick leave used no later than one pay period following the end of the regular pay period in which the paid sick leave was taken; and
(6) Be responsible for the compliance by any subcontractor with the requirements of E.O. 13706, 29 CFR part 13, and this clause.
(d) Contractors may fulfill their obligations under E.O. 13706 and 29 CFR part 13 jointly with other contractors through a multiemployer plan, or may fulfill their obligations through an individual fund, plan, or program (see 29 CFR 13.8).
(e) Withholding. The Contracting Officer will, upon his or her own action or upon written request of an authorized representative of the Department of Labor, withhold or cause to be withheld from the Contractor under this or any other Federal contract with the same Contractor, so much of the accrued payments or advances as may be considered necessary to pay employees the full amount owed to compensate for any violation of the requirements of E.O. 13706, 29 CFR part 13, or this clause, including--
(1) Any pay and/or benefits denied or lost by reason of the violation;
(2) Other actual monetary losses sustained as a direct result of the violation; and
(3) Liquidated damages.
(f) Payment suspension/contract termination/contractor debarment. 
(1) In the event of a failure to comply with E.O. 13706, 29 CFR part 13, or this clause, the contracting agency may, on its own action or after authorization or by direction of the Department of Labor and written notification to the Contractor take action to cause suspension of any further payment, advance, or guarantee of funds until such violations have ceased.
(2) Any failure to comply with the requirements of this clause may be grounds for termination for default or cause.
(3) A breach of the contract clause may be grounds for debarment as a contractor and subcontractor as provided in 29 CFR 13.52.
(g) The paid sick leave required by E.O. 13706, 29 CFR part 13, and this clause is in addition to the Contractor's obligations under the Service Contract Labor Standards statute and Wage Rate Requirements (Construction) statute, and the Contractor may not receive credit toward its prevailing wage or fringe benefit obligations under those Acts for any paid sick leave provided in satisfaction of the requirements of E.O. 13706 and 29 CFR part 13.
(h) Nothing in E.O. 13706 or 29 CFR part 13 shall excuse noncompliance with or supersede any applicable Federal or State law, any applicable law or municipal ordinance, or a collective bargaining agreement requiring greater paid sick leave or leave rights than those established under E.O. 13706 and 29 CFR part 13.
(i) Recordkeeping. 
(1) The Contractor shall make and maintain, for no less than three (3) years from the completion of the work on the contract, records containing the following information for each employee, which the Contractor shall make available upon request for inspection, copying, and transcription by authorized representatives of the Administrator of the Wage and Hour Division of the Department of Labor:
(i) Name, address, and social security number of each employee.
(ii) The employee's occupation(s) or classification(s).
(iii) The rate or rates of wages paid (including all pay and benefits provided).
(iv) The number of daily and weekly hours worked.
(v) Any deductions made.
(vi) The total wages paid (including all pay and benefits provided) each pay period.
(vii) A copy of notifications to employees of the amount of paid sick leave the employee has accrued, as required under 29 CFR 13.5(a)(2).
(viii) A copy of employees' requests to use paid sick leave, if in writing, or, if not in writing, any other records reflecting such employee requests.
(ix) Dates and amounts of paid sick leave taken by employees (unless the Contractor's paid time off policy satisfies the requirements of E.O. 13706 and 29 CFR part 13 as described in 29 CFR 13.5(f)(5), leave shall be designated in records as paid sick leave pursuant to E.O. 13706).
(x) A copy of any written responses to employees' requests to use paid sick leave, including explanations for any denials of such requests, as required under 29 CFR 13.5(d)(3).
(xi) Any records reflecting the certification and documentation the Contractor may require an employee to provide under 29 CFR 13.5(e), including copies of any certification or documentation provided by an employee.
(xii) Any other records showing any tracking of or calculations related to an employee's accrual or use of paid sick leave.
(xiii) The relevant contract.
(xiv) The regular pay and benefits provided to an employee for each use of paid sick leave.
(xv) Any financial payment made for unused paid sick leave upon a separation from employment intended, pursuant to 29 CFR 13.5(b)(5), to relieve the Contractor from the obligation to reinstate such paid sick leave as otherwise required by 29 CFR 13.5(b)(4).
(2)
(i) If the Contractor wishes to distinguish between an employee's covered and noncovered work, the Contractor shall keep records or other proof reflecting such distinctions. Only if the Contractor adequately segregates the employee's time will time spent on noncovered work be excluded from hours worked counted toward the accrual of paid sick leave. Similarly, only if the Contractor adequately segregates the employee's time may the Contractor properly refuse an employee's request to use paid sick leave on the ground that the employee was scheduled to perform noncovered work during the time he or she asked to use paid sick leave.
(ii) If the Contractor estimates covered hours worked by an employee who performs work in connection with contracts covered by the E.O. pursuant to 29 CFR 13.5(a)(1)(i) or (iii), the Contractor shall keep records or other proof of the verifiable information on which such estimates are reasonably based. Only if the Contractor relies on an estimate that is reasonable and based on verifiable information will an employee's time spent in connection with noncovered work be excluded from hours worked counted toward the accrual of paid sick leave. If the Contractor estimates the amount of time an employee spends performing in connection with contracts covered by the E.O., the Contractor shall permit the employee to use his or her paid sick leave during any work time for the Contractor.
(3) In the event the Contractor is not obligated by the Service Contract Labor Standards statute, the Wage Rate Requirements (Construction) statute, or the Fair Labor Standards Act to keep records of an employee's hours worked, such as because the employee is exempt from the Fair Labor Standards Act's minimum wage and overtime requirements, and the Contractor chooses to use the assumption permitted by 29 CFR 13.5(a)(1)(iii), the Contractor is excused from the requirement in paragraph (i)(1)(iv) of this clause and 29 CFR 13.25(a)(4) to keep records of the employee's number of daily and weekly hours worked.
(4)
(i) Records relating to medical histories or domestic violence, sexual assault, or stalking, created for purposes of E.O. 13706, whether of an employee or an employee's child, parent, spouse, domestic partner, or other individual related by blood or affinity whose close association with the employee is the equivalent of a family relationship, shall be maintained as confidential records in separate files/records from the usual personnel files.
(ii) If the confidentiality requirements of the Genetic Information Nondiscrimination Act of 2008 (GINA), section 503 of the Rehabilitation Act of 1973, and/or the Americans with Disabilities Act (ADA) apply to records or documents created to comply with the recordkeeping requirements in this contract clause, the records and documents shall also be maintained in compliance with the confidentiality requirements of the GINA, section 503 of the Rehabilitation Act of 1973, and/or ADA as described in 29 CFR 1635.9, 41 CFR 60-741.23(d), and 29 CFR 1630.14(c)(1), respectively.
(iii) The Contractor shall not disclose any documentation used to verify the need to use 3 or more consecutive days of paid sick leave for the purposes listed in 29 CFR 13.5(c)(1)(iv) (as described in 29 CFR 13.5(e)(1)(ii)) and shall maintain confidentiality about any domestic abuse, sexual assault, or stalking, unless the employee consents or when disclosure is required by law.
(5) The Contractor shall permit authorized representatives of the Wage and Hour Division to conduct interviews with employees at the worksite during normal working hours.
(6) Nothing in this contract clause limits or otherwise modifies the Contractor's recordkeeping obligations, if any, under the Service Contract Labor Standards statute, the Wage Rate Requirements (Construction) statute, the Fair Labor Standards Act, the Family and Medical Leave Act, E.O. 13658, their respective implementing regulations, or any other applicable law.
(j) Interference/discrimination. 
(1) The Contractor shall not in any manner interfere with an employee's accrual or use of paid sick leave as required by E.O. 13706 or 29 CFR part 13. Interference includes, but is not limited to--
(i) Miscalculating the amount of paid sick leave an employee has accrued;
(ii) Denying or unreasonably delaying a response to a proper request to use paid sick leave;
(iii) Discouraging an employee from using paid sick leave;
(iv) Reducing an employee's accrued paid sick leave by more than the amount of such leave used;
(v) Transferring an employee to work on contracts not covered by the E.O. to prevent the accrual or use of paid sick leave;
(vi) Disclosing confidential information contained in certification or other documentation provided to verify the need to use paid sick leave; or
(vii) Making the use of paid sick leave contingent on the employee's finding a replacement worker or the fulfillment of the Contractor's operational needs.
(2) The Contractor shall not discharge or in any other manner discriminate against any employee for--
(i) Using, or attempting to use, paid sick leave as provided for under E.O. 13706 and 29 CFR part 13;
(ii) Filing any complaint, initiating any proceeding, or otherwise asserting any right or claim under E.O. 13706 and 29 CFR part 13;
(iii) Cooperating in any investigation or testifying in any proceeding under E.O. 13706 and 29 CFR part 13; or
(iv) Informing any other person about his or her rights under E.O. 13706 and 29 CFR part 13.
(k) Notice. The Contractor shall notify all employees performing work on or in connection with a contract covered by the E.O. of the paid sick leave requirements of E.O. 13706, 29 CFR part 13, and this clause by posting a notice provided by the Department of Labor in a prominent and accessible place at the worksite so it may be readily seen by employees. Contractors that customarily post notices to employees electronically may post the notice electronically, provided such electronic posting is displayed prominently on any Web site that is maintained by the Contractor, whether external or internal, and customarily used for notices to employees about terms and conditions of employment.
(l) Disputes concerning labor standards. Disputes related to the application of E.O. 13706 to this contract shall not be subject to the general disputes clause of the contract. Such disputes shall be resolved in accordance with the procedures of the Department of Labor set forth in 29 CFR part 13. Disputes within the meaning of this contract clause include disputes between the Contractor (or any of its subcontractors) and the contracting agency, the Department of Labor, or the employees or their representatives.
(m) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (m), in all subcontracts, regardless of dollar value, that are subject to the Service Contract Labor Standards statute or the Wage Rate Requirements (Construction) statute, and are to be performed in whole or in part in the United States.

I.73  52.223-2 -- Affirmative Procurement of Biobased Products Under Service And Construction Contracts (Sep 2013)
(a) In the performance of this contract, the contractor shall make maximum use of biobased products that are United States Department of Agriculture (USDA)-designated items unless—
(1) The product cannot be acquired—
(i) Competitively within a time frame providing for compliance with the contract performance schedule;
(ii) Meeting contract performance requirements; or
(iii) At a reasonable price.
(2) The product is to be used in an application covered by a USDA categorical exemption (see 7 CFR 3201.3(e)). For example, all USDA-designated items are exempt from the preferred procurement requirement for the following:
(i) Spacecraft system and launch support equipment.
(ii) Military equipment, i.e., a product or system designed or procured for combat or combat-related missions.
(b) Information about this requirement and these products is available at http://www.biopreferred.gov .
(c) In the performance of this contract, the Contractor shall—
(1) Report to http://www.sam.gov , with a copy to the Contracting Officer, on the product types and dollar value of any USDA-designated biobased products purchased by the Contractor during the previous Government fiscal year, between October 1 and September 30; and
(2) Submit this report not later than—
(i) October 31 of each year during contract performance; and
(ii) At the end of contract performance.
(End of clause)

I.74  52.223-3 -- Hazardous Material Identification and Material Safety Data (Jan 1997)
(a) “Hazardous material,” as used in this clause, includes any material defined as hazardous under the latest version of Federal Standard No. 313 (including revisions adopted during the term of the contract).
(b) The offeror must list any hazardous material, as defined in paragraph (a) of this clause, to be delivered under this contract. The hazardous material shall be properly identified and include any applicable identification number, such as National Stock Number or Special Item Number. This information shall also be included on the Material Safety Data Sheet submitted under this contract.
	
		
	Material 
(If none, insert “None”)
	Identification No.

	 
	 

	 
	 

	 
	 

(c) This list must be updated during performance of the contract whenever the Contractor determines that any other material to be delivered under this contract is hazardous.
(d) The apparently successful offeror agrees to submit, for each item as required prior to award, a Material Safety Data Sheet, meeting the requirements of 29 CFR 1910.1200(g) and the latest version of Federal Standard No. 313, for all hazardous material identified in paragraph (b) of this clause. Data shall be submitted in accordance with Federal Standard No. 313, whether or not the apparently successful offeror is the actual manufacturer of these items. Failure to submit the Material Safety Data Sheet prior to award may result in the apparently successful offeror being considered nonresponsible and ineligible for award.
(e) If, after award, there is a change in the composition of the item(s) or a revision to Federal Standard No. 313, which renders incomplete or inaccurate the data submitted under paragraph (d) of this clause, the Contractor shall promptly notify the Contracting Officer and resubmit the data.
(f) Neither the requirements of this clause nor any act or failure to act by the Government shall relieve the Contractor of any responsibility or liability for the safety of Government, Contractor, or subcontractor personnel or property.
(g) Nothing contained in this clause shall relieve the Contractor from complying with applicable Federal, State, and local laws, codes, ordinances, and regulations (including the obtaining of licenses and permits) in connection with hazardous material.
(h) The Government’s rights in data furnished under this contract with respect to hazardous material are as follows:
(1) To use, duplicate and disclose any data to which this clause is applicable. The purposes of this right are to --
(i) Apprise personnel of the hazards to which they may be exposed in using, handling, packaging, transporting, or disposing of hazardous materials;
(ii) Obtain medical treatment for those affected by the material; and
(iii) Have others use, duplicate, and disclose the data for the Government for these purposes.
(2) To use, duplicate, and disclose data furnished under this clause, in accordance with subparagraph (h)(1) of this clause, in precedence over any other clause of this contract providing for rights in data.
(3) The Government is not precluded from using similar or identical data acquired from other sources.

I.75  52.223-5 -- Pollution Prevention and Right-to-Know Information (May 2011)
(a) Definitions. As used in this clause—
“Toxic chemical” means a chemical or chemical category in listed in 40 CFR 372.65.
(b) Federal facilities are required to comply with the provisions of the Emergency Planning and Community Right-to-Know Act of 1986 (EPCRA) (42 U.S.C. 11001-11050), and the Pollution Prevention Act of 1990 (PPA) (42 U.S.C. 13101-13109).
(c) The Contractor shall provide all information needed by the Federal facility to comply with the following:
(1) The emergency planning reporting requirements of Section 302 of EPCRA.
(2) The emergency notice requirements of Section 304 of EPCRA
(3) The list of Material Safety Data Sheets required by Section 311 of EPCRA
(4) The emergency and hazardous chemical inventory forms of Section 312 of EPCRA
(5) The toxic chemical release inventory of Section 313 of EPCRA, which includes the reduction and recycling information required by Section 6607 of PPA
(6) The toxic chemical and hazardous substance release and use reduction goals of section 2(e) of Executive Order 13423 and of Executive Order 13514.

I.76  52.223-6 -- Drug-Free Workplace (May 2001)
(a) Definitions. As used in this clause --
“Controlled substance” means a controlled substance in schedules I through V of section 202 of the Controlled Substances Act (21 U.S.C. 812) and as further defined in regulation at 21 CFR 1308.11 -- 1308.15.
“Conviction” means a finding of guilt (including a plea of nolo contendere) or imposition of sentence, or both, by any judicial body charged with the responsibility to determine violations of the Federal or State criminal drug statutes.
“Criminal drug statute” means a Federal or non-Federal criminal statute involving the manufacture, distribution, dispensing, possession, or use of any controlled substance.
“Drug-free workplace” means the site(s) for the performance of work done by the Contractor in connection with a specific contract where employees of the Contractor are prohibited from engaging in the unlawful manufacture, distribution, dispensing, possession, or use of a controlled substance.
“Employee” means an employee of a Contractor directly engaged in the performance of work under a Government contract. “Directly engaged” is defined to include all direct cost employees and any other Contractor employee who has other than a minimal impact or involvement in contract performance.
“Individual” means an offeror/contractor that has no more than one employee including the offeror/contractor.
(b) The Contractor, if other than an individual, shall -- within 30 days after award (unless a longer period is agreed to in writing for contracts of 30 days or more performance duration), or as soon as possible for contracts of less than 30 days performance duration --
(1) Publish a statement notifying its employees that the unlawful manufacture, distribution, dispensing, possession, or use of a controlled substance is prohibited in the Contractor’s workplace and specifying the actions that will be taken against employees for violations of such prohibition;
(2) Establish an ongoing drug-free awareness program to inform such employees about --
(i) The dangers of drug abuse in the workplace;
(ii) The Contractor’s policy of maintaining a drug-free workplace;
(iii) Any available drug counseling, rehabilitation, and employee assistance programs; and
(iv) The penalties that may be imposed upon employees for drug abuse violations occurring in the workplace;
(3) Provide all employees engaged in performance of the contract with a copy of the statement required by subparagraph (b)(1) of this clause;
(4) Notify such employees in writing in the statement required by subparagraph (b)(1) of this clause that, as a condition of continued employment on this contract, the employee will --
(i) Abide by the terms of the statement; and
(ii) Notify the employer in writing of the employee’s conviction under a criminal drug statute for a violation occurring in the workplace no later than 5 days after such conviction;
(5) Notify the Contracting Officer in writing within 10 days after receiving notice under subdivision (b)(4)(ii) of this clause, from an employee or otherwise receiving actual notice of such conviction. The notice shall include the position title of the employee;
(6) Within 30 days after receiving notice under subdivision (b)(4)(ii) of this clause of a conviction, take one of the following actions with respect to any employee who is convicted of a drug abuse violation occurring in the workplace:
(i) Taking appropriate personnel action against such employee, up to and including termination; or
(ii) Require such employee to satisfactorily participate in a drug abuse assistance or rehabilitation program approved for such purposes by a Federal, State, or local health, law enforcement, or other appropriate agency; and
(7) Make a good faith effort to maintain a drug-free workplace through implementation of subparagraphs (b)(1) though (b)(6) of this clause.
(c) The Contractor, if an individual, agrees by award of the contract or acceptance of a purchase order, not to engage in the unlawful manufacture, distribution, dispensing, possession, or use of a controlled substance while performing this contract.
(d) In addition to other remedies available to the Government, the Contractor’s failure to comply with the requirements of paragraph (b) or (c) of this clause may, pursuant to FAR 23.506, render the Contractor subject to suspension of contract payments, termination of the contract or default, and suspension or debarment.

I.77    FAR 52.223-7, Notice of Radioactive Materials (Jan 1997)

		
	(a) 
	The Contractor shall notify the Contracting Officer or designee, in writing, 60* days prior to the delivery of, or prior to completion of any servicing required by this contract of, items containing either:

		
	(1) 
	radioactive material requiring specific licensing under the regulations issued pursuant to the Atomic Energy Act of 1954, as amended, as set forth in Title 10 of the Code of Federal Regulations, in effect on the date of this contract, or

		
	(2) 
	other radioactive material not requiring specific licensing in which the specific activity is greater than 0.002 microcuries per gram or the activity per item equals or exceeds 0.01 microcuries.

Such notice shall specify the part or parts of the items which contain radioactive materials, a description of the materials, the name and activity of the isotope, the manufacturer of the materials, and any other information known to the Contractor which will put users of the items on notice as to the hazards involved (OMB No. 9000-0107).
* The Contracting Officer shall insert the number of days required in advance of delivery of the item or completion of the servicing to assure that required licenses are obtained and appropriate personnel are notified to institute any necessary safety and health precautions.  See FAR 23.601(d).
		
	(b) 
	If there has been no change affecting the quantity of activity, or the characteristics and composition of the radioactive material from deliveries under this contract or prior contracts, the Contractor may request that the Contracting Officer or designee waive the notice requirement in paragraph (a) of this clause.  Any such request shall −

		
	(1) 
	be submitted in writing;

		
	(2) 
	state that the quantity of activity, characteristics, and composition of the radioactive material have not changed; and

		
	(3) 
	cite the contract number on which the prior notification was submitted and the contracting office to which it was submitted.

		
	(c) 
	All items, parts, or subassemblies which contain radioactive materials in which the specific activity is greater than 0.002 microcuries per gram or activity per item equals or exceeds 0.01 microcuries, and all containers in which such items, parts or subassemblies are delivered to the Government shall be clearly marked and labeled as required by the latest revision of MIL-STD 129 in effect on the date of the contract.

		
	(d) 
	This clause, including this paragraph (d), shall be inserted in all subcontracts for radioactive materials meeting the criteria in paragraph (a) of this clause.

I.78    FAR 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (May 2008) 
		
	(a) 
	Definitions. As used in this clause −

“Postconsumer material” means a material or finished product that has served its intended use and has been discarded for disposal or recovery, having completed its life as a consumer item. Postconsumer material is a part of the broader category of “recovered material.” 
“Recovered material” means waste materials and by-products recovered or diverted from solid waste, but the term does not include those materials and by-products generated from, and commonly reused within, an original manufacturing process. 
		
	(b) 
	The Contractor, on completion of this contract, shall − 

		
	(1) 
	Estimate the percentage of the total recovered material content for EPA designated item(s) delivered and/or used in contract performance, including, if applicable, the percentage of post-consumer material content; and 

		
	(2) 
	Submit this estimate to the Contracting Officer.

I.79  52.223-10 -- Waste Reduction Program (May 2011)
(a) Definitions. As used in this clause—
“Recycling” means the series of activities, including collection, separation, and processing, by which products or other materials are recovered from the solid waste stream for use in the form of raw materials in the manufacture of products other than fuel for producing heat or power by combustion.
“Waste prevention” means any change in the design, manufacturing, purchase, or use of materials or products (including packaging) to reduce their amount or toxicity before they are discarded. Waste prevention also refers to the reuse of products or materials.
“Waste reduction” means preventing or decreasing the amount of waste being generated through waste prevention, recycling, or purchasing recycled and environmentally preferable products.
(b) Consistent with the requirements of section 3(e) of Executive Order 13423, the Contractor shall establish a program to promote cost-effective waste reduction in all operations and facilities covered by this contract.

I.80  52.223-13 – Acquisition of EPEAT® - Registered Imaging Equipment (Jun 2014)
(a) Definitions. As used in this clause--
“Imaging equipment” means the following products:
(1) Copier--A commercially available imaging product with a sole function of the production of hard copy duplicates from graphic hard-copy originals. The unit is capable of being powered from a wall outlet or from a data or network connection. This definition is intended to cover products that are marketed as copiers or upgradeable digital copiers (UDCs).
(2) Digital duplicator--A commercially available imaging product that is sold in the market as a fully automated duplicator system through the method of stencil duplicating with digital reproduction functionality. The unit is capable of being powered from a wall outlet or from a data or network connection. This definition is intended to cover products that are marketed as digital duplicators.
(3) Facsimile machine (fax machine)--A commercially available imaging product whose primary functions are scanning hard-copy originals for electronic transmission to remote units and receiving similar electronic transmissions to produce hard-copy output. Electronic transmission is primarily over a public telephone system but also may be via computer network or the Internet. The product also may be capable of producing hard copy duplicates. The unit is capable of being powered from a wall outlet or from a data or network connection. This definition is intended to cover products that are marketed as fax machines.
(4) Mailing machine--A commercially available imaging product that serves to print postage onto mail pieces. The unit is capable of being powered from a wall outlet or from a data or network connection. This definition is intended to cover products that are marketed as mailing machines.
(5) Multifunction device (MFD)--A commercially available imaging product, which is a physically integrated device or a combination of functionally integrated components, that performs two or more of the core functions of copying, printing, scanning, or faxing. The copy functionality as addressed in this definition is considered to be distinct from single-sheet convenience copying offered by fax machines. The unit is capable of being powered from a wall outlet or from a data or network connection. This definition is intended to cover products that are marketed as MFDs or multifunction products.
(6) Printer--A commercially available imaging product that serves as a hard-copy output device and is capable of receiving information from single-user or networked computers, or other input devices (e.g., digital cameras). The unit is capable of being powered from a wall outlet or from a data or network connection. This definition is intended to cover products that are marketed as printers, including printers that can be upgraded into MFDs in the field.
(7) Scanner--A commercially available imaging product that functions as an electro-optical device for converting information into electronic images that can be stored, edited, converted, or transmitted, primarily in a personal computing environment. The unit is capable of being powered from a wall outlet or from a data or network connection. This definition is intended to cover products that are marketed as scanners.
(b) Under this contract, the Contractor shall deliver, furnish for Government use, or furnish for Contractor use at a Federally controlled facility, only imaging equipment that, at the time of submission of proposals and at the time of award, was EPEAT® bronze-registered or higher.
(c) For information about EPEAT®, see www.epa.gov/epeat.

I.81  52.223-14 – Acquisition of EPEAT® -Registered Televisions (Jun 2014)
(a) Definitions. As used in this clause—
“Television or TV” means a commercially available electronic product designed primarily for the reception and display of audiovisual signals received from terrestrial, cable, satellite, Internet Protocol TV (IPTV), or other digital or analog sources. A TV consists of a tuner/receiver and a display encased in a single enclosure. The product usually relies upon a cathode-ray tube (CRT), liquid crystal display (LCD), plasma display, or other display technology. Televisions with computer capability (e.g., computer input port) may be considered to be a TV as long as they are marketed and sold to consumers primarily as televisions.
(b) Under this contract, the Contractor shall deliver, furnish for Government use, or furnish for Contractor use at a Federally controlled facility, only televisions that, at the time of submission of proposals and at the time of award, were EPEAT® bronze-registered or higher.
(c) For information about EPEAT®, see www.epa.gov/epeat.

I.82  52.223-15 – Energy Efficiency in Energy-Consuming Products (Dec 2007)
(a) Definition. As used in this clause--
“Energy-efficient product”—
(1) Means a product that—
(i) Meets Department of Energy and Environmental Protection Agency criteria for use of the Energy Star trademark label; or
(ii) Is in the upper 25 percent of efficiency for all similar products as designated by the Department of Energy’s Federal Energy Management Program.
(2) The term “product” does not include any energy-consuming product or system designed or procured for combat or combat-related missions (42 U.S.C. 8259b).
(b) The Contractor shall ensure that energy-consuming products are energy efficient products (i.e., ENERGY STAR® products or FEMP-designated products) at the time of contract award, for products that are—
(1) Delivered;
(2) Acquired by the Contractor for use in performing services at a Federally-controlled facility;
(3) Furnished by the Contractor for use by the Government; or
(4) Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance.
(c) The requirements of paragraph (b) apply to the Contractor (including any subcontractor) unless—
(1) The energy-consuming product is not listed in the ENERGY STAR® Program or FEMP; or
(2) Otherwise approved in writing by the Contracting Officer.
(d) Information about these products is available for—
(1) ENERGY STAR® at http://www.energystar.gov/products; and
(2) FEMP at http://www1.eere.energy.gov/femp/procurement/eep_requirements.html.

I.83  52.223-16 – Acquisition of EPEAT®-Registered Personal Computer Products (Oct 2015)
(a) Definitions. As used in this clause—
“Computer” means a device that performs logical operations and processes data. Computers are composed of, at a minimum:
(1) A central processing unit (CPU) to perform operations;
(2) User input devices such as a keyboard, mouse, digitizer, or game controller; and
(3) A computer display screen to output information. Computers include both stationary and portable units, including desktop computers, integrated desktop computers, notebook computers, thin clients, and workstations. Although computers must be capable of using input devices and computer displays, as noted in (2) and (3) above, computer systems do not need to include these devices on shipment to meet this definition. This definition does not include server computers, gaming consoles, mobile telephones, portable hand-held calculators, portable digital assistants (PDAs), MP3 players, or any other mobile computing device with displays less than 4 inches, measured diagonally.
“Computer display” means a display screen and its associated electronics encased in a single housing or within the computer housing (e.g., notebook or integrated desktop computer) that is capable of displaying output information from a computer via one or more inputs such as a VGA, DVI, USB, DisplayPort, and/or IEEE 1394-2008TM, Standard for High Performance Serial Bus. Examples of computer display technologies are the cathode-ray tube (CRT) and liquid crystal display (LCD).
“Desktop computer” means a computer where the main unit is intended to be located in a permanent location, often on a desk or on the floor. Desktops are not designed for portability and utilize an external computer display, keyboard, and mouse. Desktops are designed for a broad range of home and office applications.
“Integrated desktop computer” means a desktop system in which the computer and computer display function as a single unit that receives its AC power through a single cable. Integrated desktop computers come in one of two possible forms:
(1) A system where the computer display and computer are physically combined into a single unit; or
(2) A system packaged as a single system where the computer display is separate but is connected to the main chassis by a DC power cord and both the computer and computer display are powered from a single power supply. As a subset of desktop computers, integrated desktop computers are typically designed to provide similar functionality as desktop systems.
“Notebook computer” means a computer designed specifically for portability and to be operated for extended periods of time either with or without a direct connection to an AC power source. Notebooks must utilize an integrated computer display and be capable of operation off of an integrated battery or other portable power source. In addition, most notebooks use an external power supply and have an integrated keyboard and pointing device. Notebook computers are typically designed to provide similar functionality to desktops, including operation of software similar in functionality to that used in desktops. Docking stations are considered accessories for notebook computers, not notebook computers. Tablet PCs, which may use touch-sensitive screens along with, or instead of, other input devices, are considered notebook computers.
“Personal computer product” means a computer, computer display, desktop computer, integrated desktop computer, or notebook computer.
(b) Under this contract, the Contractor shall deliver, furnish for Government use, or furnish for Contractor use at a Federally controlled facility, only personal computer products that, at the time of submission of proposals and at the time of award, were EPEAT® bronze-registered or higher.
(c) For information about EPEAT®, see www.epa.gov/epeat.

I.84  52.223-17 – Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts (Aug 2018)
(a) In the performance of this contract, the Contractor shall make maximum use of products containing recovered materials that are EPA-designated items unless the product cannot be acquired—
(1) Competitively within a timeframe providing for compliance with the contract performance schedule;
(2) Meeting contract performance requirements; or
(3) At a reasonable price.
(b) Information about this requirement is available at EPA’s Comprehensive Procurement Guidelines web site. The list of EPA-designate items is available at https://www.epa.gov/smm/comprehensive-procurement-guideline-cpg-program .

I.85  52.223-18 – Encouraging Contractor Policies to Ban Text Messaging While Driving (Aug 2011)
(a) Definitions. As used in this clause--
“Driving”—
(1) Means operating a motor vehicle on an active roadway with the motor running, including while temporarily stationary because of traffic, a traffic light, stop sign, or otherwise.
(2) Does not include operating a motor vehicle with or without the motor running when one has pulled over to the side of, or off, an active roadway and has halted in a location where one can safely remain stationary.
“Text messaging” means reading from or entering data into any handheld or other electronic device, including for the purpose of short message service texting, e-mailing, instant messaging, obtaining navigational information, or engaging in any other form of electronic data retrieval or electronic data communication. The term does not include glancing at or listening to a navigational device that is secured in a commercially designed holder affixed to the vehicle, provided that the destination and route are programmed into the device either before driving or while stopped in a location off the roadway where it is safe and legal to park.
(b) This clause implements Executive Order 13513, Federal Leadership on Reducing Text Messaging while Driving, dated October 1, 2009.
(c) The Contractor is encouraged to—
(1) Adopt and enforce policies that ban text messaging while driving—
(i) Company-owned or -rented vehicles or Government-owned vehicles; or
(ii) Privately-owned vehicles when on official Government business or when performing any work for or on behalf of the Government.
(2) Conduct initiatives in a manner commensurate with the size of the business, such as—
(i) Establishment of new rules and programs or re-evaluation of existing programs to prohibit text messaging while driving; and
(ii) Education, awareness, and other outreach to employees about the safety risks associated with texting while driving.
(d) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (d), in all subcontracts that exceed the micro-purchase threshold.

I.86  52.223-19 -- Compliance with Environmental Management Systems (May 2011)
The Contractor's work under this contract shall conform with all operational controls identified in the applicable agency or facility Environmental Management Systems and provide monitoring and measurement information necessary for the Government to address environmental performance relative to the goals of the Environmental Management Systems.

I.87  52.223-20 – Aerosols (Jun 2016)
(a) Definitions. As used in this clause--
“Global warming potential” means how much a given mass of a chemical contributes to global warming over a given time period compared to the same mass of carbon dioxide. Carbon dioxide’s global warming potential is defined as 1.0.
“High global warming potential hydrofluorocarbons” means any hydrofluorocarbons in a particular end use for which EPA’s Significant New Alternatives Policy (SNAP) program has identified other acceptable alternatives that have lower global warming potential. The SNAP list of alternatives is found at 40 CFR part 82, subpart G. with supplemental tables of alternatives available at http://www.epa.gov/snap/). 
“Hydrofluorocarbons” means compounds that contain only hydrogen, fluorine, and carbon.
(b) Unless otherwise specified in the contract, the Contractor shall reduce its use, release, or emissions of high global warming potential hydrofluorocarbons, when feasible, from aerosol propellants or solvents under this contract. When determining feasibility of using a particular alternative, the Contractor shall consider environmental, technical, and economic factors such as--
(1) In-use emission rates, energy efficiency;
(2) Safety, such as flammability or toxicity;
(3) Ability to meet technical performance requirements; and
(4) Commercial availability at a reasonable cost.
(c) The Contractor shall refer to EPA’s SNAP program to identify alternatives. The SNAP list of alternatives is found at 40 CFR part 82, subpart G, with supplemental tables available at http://www.epa.gov/snap/. 

I.88  52.223-21 -- Foams (Jun 2016)
(a) Definitions. As used in this clause--
“Global warming potential” means how much a given mass of a chemical contributes to global warming over a given time period compared to the same mass of carbon dioxide. Carbon dioxide’s global warming potential is defined as 1.0.
“High global warming potential hydrofluorocarbons” means any hydrofluorocarbons in a particular end use for which EPA’s Significant New Alternatives Policy (SNAP) program has identified other acceptable alternatives that have lower global warming potential. The SNAP list of alternatives is found at 40 CFR part 82, subpart G. with supplemental tables of alternatives available at http://www.epa.gov/snap/). 
“Hydrofluorocarbons” means compounds that contain only hydrogen, fluorine, and carbon.
(b) Unless otherwise specified in the contract, the Contractor shall reduce its use, release, and emissions of high global warming potential hydrofluorocarbons and refrigerant blends containing hydrofluorocarbons, when feasible, from foam blowing agents, under this contract. When determining feasibility of using a particular alternative, the Contractor shall consider environmental, technical, and economic factors such as--
(1) In-use emission rates, energy efficiency, and safety;
(2) Ability to meet performance requirements; and;
(3) Commercial availability at a reasonable cost.
(c) The Contractor shall refer to EPA’s SNAP program to identify alternatives. The SNAP list of alternatives is found at 40 CFR part 82, subpart G, with supplemental tables available at http://www.epa.gov/snap/. 

I.89  52.224-1 -- Privacy Act Notification (Apr 1984)
The Contractor will be required to design, develop, or operate a system of records on individuals, to accomplish an agency function subject to the Privacy Act of 1974, Public Law 93-579, December 31, 1974 (5 U.S.C.552a) and applicable agency regulations. Violation of the Act may involve the imposition of criminal penalties.

I.90  52.224-2 -- Privacy Act (Apr 1984)
(a) The Contractor agrees to --
(1) Comply with the Privacy Act of 1974 (the Act) and the agency rules and regulations issued under the Act in the design, development, or operation of any system of records on individuals to accomplish an agency function when the contract specifically identifies --
(i) The systems of records; and
(ii) The design, development, or operation work that the contractor is to perform;
(2) Include the Privacy Act notification contained in this contract in every solicitation and resulting subcontract and in every subcontract awarded without a solicitation, when the work statement in the proposed subcontract requires the redesign, development, or operation of a system of records on individuals that is subject to the Act; and
(3) Include this clause, including this subparagraph (3), in all subcontracts awarded under this contract which requires the design, development, or operation of such a system of records.
(b) In the event of violations of the Act, a civil action may be brought against the agency involved when the violation concerns the design, development, or operation of a system of records on individuals to accomplish an agency function, and criminal penalties may be imposed upon the officers or employees of the agency when the violation concerns the operation of a system of records on individuals to accomplish an agency function. For purposes of the Act, when the contract is for the operation of a system of records on individuals to accomplish an agency function, the Contractor is considered to be an employee of the agency.
(c)
(1) “Operation of a system of records,” as used in this clause, means performance of any of the activities associated with maintaining the system of records, including the collection, use, and dissemination of records.
(2) “Record,” as used in this clause, means any item, collection, or grouping of information about an individual that is maintained by an agency, including, but not limited to, education, financial transactions, medical history, and criminal or employment history and that contains the person’s name, or the identifying number, symbol, or other identifying particular assigned to the individual, such as a fingerprint or voiceprint or a photograph.
(3) “System of records on individuals,” as used in this clause, means a group of any records under the control of any agency from which information is retrieved by the name of the individual or by some identifying number, symbol, or other identifying particular assigned to the individual.

I.91  52.225-1 -- Buy American—Supplies (May 2014)
(a) Definitions. As used in this clause--
“Commercially available off-the-shelf (COTS) item”—
(1) Means any item of supply (including construction material) that is—
(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);
(ii) Sold in substantial quantities in the commercial marketplace; and
(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and
(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.
“Component” means an article, material, or supply incorporated directly into an end product.
“Cost of components” means--
(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the end product (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or
(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the end product.
“Domestic end product” means—
(1) An unmanufactured end product mined or produced in the United States;
(2) An end product manufactured in the United States, if—
(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind as those that the agency determines are not mined, produced, or manufactured in sufficient and reasonably available commercial quantities of a satisfactory quality are treated as domestic. Scrap generated, collected, and prepared for processing in the United States is considered domestic; or
(ii) The end product is a COTS item.
“End product” means those articles, materials, and supplies to be acquired under the contract for public use.
“Foreign end product” means an end product other than a domestic end product.
“United States” means the 50 States, the District of Columbia, and outlying areas.
(b) 41 U.S.C. chapter 83, Buy American, provides a preference for domestic end products for supplies acquired for use in the United States. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for an end product that is a COTS item (See 12.505(a)(1)).
(c) Offerors may obtain from the Contracting Officer a list of foreign articles that the Contracting Officer will treat as domestic for this contract.
(d) The Contractor shall deliver only domestic end products except to the extent that it specified delivery of foreign end products in the provision of the solicitation entitled “Buy American Certificate.”

I.92 52.225-9 -- Buy American–Construction Materials (May 2014)
(a) Definitions. As used in this clause--
“Commercially available off-the-shelf (COTS) item”—
(1) Means any item of supply (including construction material) that is—
(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);
(ii) Sold in substantial quantities in the commercial marketplace; and
(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and
(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.
“Component” means an article, material, or supply incorporated directly into a construction material.
“Construction material” means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.
“Cost of components” means--
(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or
(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.
“Domestic construction material” means—
(1) An unmanufactured construction material mined or produced in the United States;
(2) A construction material manufactured in the United States, if—
(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or
(ii) The construction material is a COTS item.
“Foreign construction material” means a construction material other than a domestic construction material.
“United States” means the 50 States, the District of Columbia, and outlying areas.
(b) Domestic preference.
(1) This clause implements the 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.
(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows: ______ [Contracting Officer to list applicable excepted materials or indicate “none”]
(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that
(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;
(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or
(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.
(c) Request for determination of inapplicability of the Buy American statute. 
(1)
(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including--
(A) A description of the foreign and domestic construction materials;
(B) Unit of measure;
(C) Quantity;
(D) Price;
(E) Time of delivery or availability;
(F) Location of the construction project;
(G) Name and address of the proposed supplier; and
(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.
(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.
(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).
(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.
(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.
(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.
(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:
Foreign and Domestic Construction Materials Price Comparison
	
				
	Construction material description
	Unit of measure
	Quantity
	Price (dollars) *

	Item 1
	 
	 
	 

	Foreign construction material
	 
	 
	 

	Domestic construction material
	 
	 
	 

	Item 2
	 
	 
	 

	Foreign construction material
	 
	 
	 

	Domestic construction material
	 
	 
	 

[List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.] 
[Include other applicable supporting information.]
[*Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).]

I.93  52.225-11, Buy American – Construction Materials Under Trade Agreements (Oct 2016) 
		
	(a) 
	Definitions. As used in this clause − 

“Caribbean Basin country construction material” means a construction material that −
		
	(1) 
	Is wholly the growth, product, or manufacture of a Caribbean Basin country; or

		
	(2) 
	In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a Caribbean Basin country into a new and different construction material distinct from the materials from which it was transformed.

“Commercially available off-the-shelf (COTS) item” means − 
(1) Means any item of supply (including construction material) that is −
		
	(i) 
	A commercial item (as defined in paragraph (1) of the definition at FAR 2.101); 

		
	(ii) 
	Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and
		
	(2) 
	Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products. 

“Component” means an article, material, or supply incorporated directly into a construction material.
“Construction material” means an article, material, or supply brought to the construction site by the Contractor or subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.
“Cost of components” means −
		
	(1) 
	For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

		
	(2) 
	For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

“Designated country” means any of the following countries:
		
	(1) 
	A World Trade Organization Government Procurement Agreement (WTO GPA) country (Armenia, Aruba, Austria, Belgium, Bulgaria, Canada, Croatia, Cyprus, Czech Republic, Denmark, Estonia, Finland, France, Germany, Greece, Hong Kong, Hungary, Iceland, Ireland, Israel, Italy, Japan, Korea (Republic of), Latvia, Liechtenstein, Lithuania, Luxembourg, Malta, Moldova, Montenegro, Netherlands, New Zealand, Norway, Poland, Portugal, Romania, Singapore, Slovak Republic, Slovenia, Spain, Sweden, Switzerland, Taiwan, Ukraine, or United Kingdom);

		
	(2) 
	A Free Trade Agreement (FTA) country (Australia, Bahrain, Canada, Chile, Colombia, Costa Rica, Dominican Republic, El Salvador, Guatemala, Honduras, Korea (Republic of), Mexico, Morocco, Nicaragua, Oman, Panama, Peru, or Singapore);

		
	(3) 
	A least developed country (Afghanistan, Angola, Bangladesh, Benin, Bhutan, Burkina Faso, Burundi, Cambodia, Central African Republic, Chad, Comoros, Democratic Republic of Congo, Djibouti, Equatorial Guinea, Eritrea, Ethiopia, Gambia, Guinea, Guinea-Bissau, Haiti, Kiribati, Laos, Lesotho, Liberia, Madagascar, Malawi, Mali, Mauritania, Mozambique, Nepal, Niger, Rwanda, Samoa, Sao Tome and Principe, Senegal, Sierra Leone, Solomon Islands, Somalia, South Sudan, Tanzania, Timor-Leste, Togo, Tuvalu, Uganda, Vanuatu, Yemen, or Zambia); or

		
	(4) 
	A Caribbean Basin country (Antigua and Barbuda, Aruba, Bahamas, Barbados, Belize, Bonaire, British Virgin Islands, Curacao, Dominica, Grenada, Guyana, Haiti, Jamaica, Montserrat, Saba, St. Kitts and Nevis, St. Lucia, St. Vincent and the Grenadines, Sint Eustatius, Sint Maarten, or Trinidad and Tobago).

“Designated country construction material” means a construction material that is a WTO GPA country construction material, an FTA country construction material, a least developed country construction material, or a Caribbean Basin country construction material.
“Domestic construction material” means −
		
	(1) 
	An unmanufactured construction material mined or produced in the United States;

		
	(2) 
	A construction material manufactured in the United States, if −

		
	(i) 
	The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

		
	(ii) 
	The construction material is a COTS item.

“Foreign construction material” means a construction material other than a domestic construction material.”
“Free Trade Agreement country construction material” means a construction material that:
		
	(1) 
	Is wholly the growth, product, or manufacture of a Free Trade Agreement (FTA) country; or

		
	(2) 
	In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a FTA country into a new and different construction material distinct from the materials from which it was transformed.

 “Least developed country construction material” means a construction material that:
		
	(1) 
	Is wholly the growth, product, or manufacture of a least developed country; or

		
	(2) 
	In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a least developed country into a new and different construction material distinct from the materials from which it was transformed.

“United States” means the 50 States, the District of Columbia, and outlying areas.
“WTO GPA country construction material” means a construction material that:
		
	(1) 
	Is wholly the growth, product, or manufacture of a WTO GPA country; or

		
	(2) 
	In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a WTO GPA country into a new and different construction material distinct from the materials from which it was transformed.

		
	(b) 
	Construction materials.

		
	(1) 
	This clause implements 41 U.S.C. chapter 83, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). In addition, the Contracting Officer has determined that the WTO GPA and Free Trade Agreements (FTAs) apply to this acquisition. Therefore, the Buy American restrictions are waived for designated country construction materials. 

		
	(2) 
	The Contractor shall use only domestic or designated country construction material in performing this contract, except as provided in paragraphs (b)(3) and (b)(4) of this clause.

		
	(3) 
	The requirement in paragraph (b)(2) of this clause does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows:  None

		
	(4) 
	The Contracting Officer may add other foreign construction material to the list in paragraph (b)(3) of this clause if the Government determines that −

		
	(i) 
	The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the restrictions of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

		
	(ii) 
	The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

		
	(iii) 
	The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

		
	(c) 
	Request for determination of inapplicability of the Buy American statute.

(1)
		
	(i) 
	Any Contractor request to use foreign construction material in accordance with paragraph (b)(4) of this clause shall include adequate information for Government evaluation of the request, including −

		
	(A) 
	A description of the foreign and domestic construction materials;

		
	(B) 
	Unit of measure;

		
	(C)
	Quantity;

		
	(D) 
	Price;

		
	(E) 
	Time of delivery or availability;

		
	(F) 
	Location of the construction project;

		
	(G) 
	Name and address of the proposed supplier; and

		
	(H) 
	A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

		
	(ii) 
	A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

		
	(iii) 
	The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

		
	(iv) 
	Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

		
	(2) 
	If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(4)(i) of this clause.

		
	(3) 
	Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

		
	(d) 
	Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers: 

	
				
	Foreign and Domestic Construction Materials Price Comparison

	Construction Material Description
	Unit of  
Measure
	Quantity
	Price (Dollars)*

	Item 1

	Foreign construction material
	_______
	_______
	__          _____

	Domestic construction material
	_______
	_______
	____         ___

	Item 2

	Foreign construction material
	_______
	_______
	____         ___

	Domestic construction material
	_______
	_______
	____         ___

[List name, address, telephone number, and contact for suppliers surveyed.  Attach copy of response; if oral, attach summary.] 
[Include other applicable supporting information.] 
[* Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).] 

I.94  52.225-13 -- Restrictions on Certain Foreign Purchases (Jun 2008)
(a) Except as authorized by the Office of Foreign Assets Control (OFAC) in the Department of the Treasury, the Contractor shall not acquire, for use in the performance of this contract, any supplies or services if any proclamation, Executive order, or statute administered by OFAC, or if OFAC’s implementing regulations at 31 CFR chapter V, would prohibit such a transaction by a person subject to the jurisdiction of the United States. 
(b) Except as authorized by OFAC, most transactions involving Cuba, Iran, and Sudan are prohibited, as are most imports from Burma or North Korea, into the United States or its outlying areas. Lists of entities and individuals subject to economic sanctions are included in OFAC’s List of Specially Designated Nationals and Blocked Persons at http://www.treas.gov/offices/enforcement/ofac/sdn/. More information about these restrictions, as well as updates, is available in the OFAC’s regulations at 31 CFR chapter V and/or on OFAC’s website at http://www.treas.gov/offices/enforcement/ofac. 
(c) The Contractor shall insert this clause, including this paragraph (c), in all subcontracts.

I.95  52.227-1 -- Authorization and Consent (Dec 2007)
(a) The Government authorizes and consents to all use and manufacture, in performing this contract or any subcontract at any tier, of any invention described in and covered by a United States patent—
(1) Embodied in the structure or composition of any article the delivery of which is accepted by the Government under this contract; or
(2) Used in machinery, tools, or methods whose use necessarily results from compliance by the Contractor or a subcontractor with (i) specifications or written provisions forming a part of this contract or (ii) specific written instructions given by the Contracting Officer directing the manner of performance, the entire liability to the Government for infringement of a patent of the United States shall be determined solely by the provisions of the indemnity clause, if any, included in this contract or any subcontract hereunder (including any lower-tier subcontract), and the Government assumes liability for all other infringement to the extent of the authorization and consent herein above granted.
(b) The Contractor shall include the substance of this clause, including this paragraph (b), in all subcontracts that are expected to exceed the simplified acquisition threshold. However, omission of this clause from any subcontract, including those at or below the simplified acquisition threshold, does not affect this authorization and consent.

I.96  52.227-2 -- Notice and Assistance Regarding Patent and Copyright Infringement (Dec. 2007)
(a) The Contractor shall report to the Contracting Officer, promptly and in reasonable written detail, each notice or claim of patent or copyright infringement based on the performance of this contract of which the Contractor has knowledge.
(b) In the event of any claim or suit against the Government on account of any alleged patent or copyright infringement arising out of the performance of this contract or out of the use of any supplies furnished or work or services performed under this contract, the Contractor shall furnish to the Government, when requested by the Contracting Officer, all evidence and information in the Contractor’s possession pertaining to such claim or suit. Such evidence and information shall be furnished at the expense of the Government except where the Contractor has agreed to indemnify the Government.
(c) The Contractor shall include the substance of this clause, including this paragraph (c), in all subcontracts that are expected to exceed the simplified acquisition threshold.

I.97  52.227-3 -- Patent Indemnity (Apr 1984)
(a) The Contractor shall indemnify the Government and its officers, agents, and employees against liability, including costs, for infringement of any United States patent (except a patent issued upon an application that is now or may hereafter be withheld from issue pursuant to a Secrecy Order under 35 U.S.C. 181) arising out of the manufacture or delivery of supplies, the performance of services, or the construction, alteration, modification, or repair of real property (hereinafter referred to as “construction work”) under this contract, or out of the use or disposal by or for the account of the Government of such supplies or construction work.
(b) This indemnity shall not apply unless the Contractor shall have been informed as soon as practicable by the Government of the suit or action alleging such infringement and shall have been given such opportunity as is afforded by applicable laws, rules, or regulations to participate in its defense. Further, this indemnity shall not apply to --
(1) An infringement resulting from compliance with specific written instructions of the Contracting Officer directing a change in the supplies to be delivered or in the materials or equipment to be used, or directing a manner of performance of the contract not normally used by the Contractor;
(2) An infringement resulting from addition to or change in supplies or components furnished or construction work performed that was made subsequent to delivery or performance; or
(3) A claimed infringement that is unreasonably settled without the consent of the Contractor, unless required by final decree of a court of competent jurisdiction.

I.98  52.227-10 -- Filing of Patent Applications -- Classified Subject Matter (Dec 2007)
(a) Before filing or causing to be filed a patent application in the United States disclosing any subject matter of this contract classified “Secret” or higher, the Contractor shall, citing the 30-day provision below, transmit the proposed application to the Contracting Officer. The Government shall determine whether, for reasons of national security, the application should be placed under an order of secrecy, sealed in accordance with the provision of 35 U.S.C. 181-188, or the issuance of a patent otherwise delayed under pertinent United States statutes or regulations. The Contractor shall observe any instructions of the Contracting Officer regarding the manner of delivery of the patent application to the United States Patent Office, but the Contractor shall not be denied the right to file the application. If the Contracting Officer shall not have given any such instructions within 30 days from the date of mailing or other transmittal of the proposed application, the Contractor may file the application.
(b) Before filing a patent application in the United States disclosing any subject matter of this contract classified “Confidential,’’ the Contractor shall furnish to the Contracting Officer a copy of the application for Government determination whether, for reasons of national security, the application should be placed under an order of secrecy or the issuance of a patent should be otherwise delayed under pertinent United States statutes or regulations.
(c) Where the subject matter of this contract is classified for reasons of security, the Contractor shall not file, or cause to be filed, in any country other than in the United States as provided in paragraphs (a) and (b) of this clause, an application or registration for a patent containing any of the subject matter of this contract without first obtaining written approval of the Contracting Officer.
(d) When filing any patent application coming within the scope of this clause, the Contractor shall observe all applicable security regulations covering the transmission of classified subject matter and shall promptly furnish to the Contracting Officer the serial number, filing date, and name of the country of any such application. When transmitting the application to the United States Patent Office, the Contractor shall by separate letter identify by agency and number the contract or contracts that require security classification markings to be placed on the application.
(e) The Contractor shall include the substance of this clause, including this paragraph (e), in all subcontracts that cover or are likely to cover classified subject matter.

I.99  52.227-16 -- Additional Data Requirements (Jun 1987)
(a) In addition to the data (as defined in the clause at 52.227-14, Rights in Data -- General clause or other equivalent included in this contract) specified elsewhere in this contract to be delivered, the Contracting Officer may, at any time during contract performance or within a period of 3 years after acceptance of all items to be delivered under this contract, order any data first produced or specifically used in the performance of this contract.
(b) The Rights in Data -- General clause or other equivalent included in this contract is applicable to all data ordered under this Additional Data Requirements clause. Nothing contained in this clause shall require the Contractor to deliver any data the withholding of which is authorized by the Rights in Data -- General or other equivalent clause of this contract, or data which are specifically identified in this contract as not subject to this clause.
(c) When data are to be delivered under this clause, the Contractor will be compensated for converting the data into the prescribed form, for reproduction, and for delivery.
(d) The Contracting Officer may release the Contractor from the requirements of this clause for specifically identified data items at any time during the 3-year period set forth in paragraph (a) of this clause.

I.100  52.228-5 -- Insurance -- Work on a Government Installation (Jan 1997)
(a) The Contractor shall, at its own expense, provide and maintain during the entire performance of this contract, at least the kinds and minimum amounts of insurance required in the Schedule or elsewhere in the contract.
(b) Before commencing work under this contract, the Contractor shall notify the Contracting Officer in writing that the required insurance has been obtained. The policies evidencing required insurance shall contain an endorsement to the effect that any cancellation or any material change adversely affecting the Government’s interest shall not be effective --
(1) For such period as the laws of the State in which this contract is to be performed prescribe; or
(2) Until 30 days after the insurer or the Contractor gives written notice to the Contracting Officer, whichever period is longer.
(c) The Contractor shall insert the substance of this clause, including this paragraph (c), in subcontracts under this contract that require work on a Government installation and shall require subcontractors to provide and maintain the insurance required in the Schedule or elsewhere in the contract. The Contractor shall maintain a copy of all subcontractors’ proofs of required insurance, and shall make copies available to the Contracting Officer upon request.

I.101  52.232-11 -- Extras (Apr 1984)
Except as otherwise provided in this contract, no payment for extras shall be made unless such extras and the price therefor have been authorized in writing by the Contracting Officer.

I.102  52.232-9 -- Limitation on Withholding of Payments (Apr 1984)
If more than one clause or Schedule term of this contract authorizes the temporary withholding of amounts otherwise payable to the Contractor for supplies delivered or services performed, the total of the amounts withheld at any one time shall not exceed the greatest amount that may be withheld under any one clause or Schedule term at that time; provided, that this limitation shall not apply to --
(a) Withholdings pursuant to any clause relating to wages or hours of employees;
(b) Withholdings not specifically provided for by this contract;
(c) The recovery of overpayments; and
(d) Any other withholding for which the Contracting Officer determines that this limitation is inappropriate.

I.103  52.232-17 -- Interest (May 2014)
(a) Except as otherwise provided in this contract under a Price Reduction for Defective Certified Cost or Pricing Data clause or a Cost Accounting Standards clause, all amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in 41 U.S.C. 7109, which is applicable to the period in which the amount becomes due, as provided in paragraph (e) of this clause, and then at the rate applicable for each six-month period as fixed by the Secretary until the amount is paid.
(b) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract.
(c) Final Decisions. The Contracting Officer will issue a final decision as required by 33.211 if—
(1) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt in a timely manner;
(2) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or 
(3) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see 32.607-2).
(d) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment.
(e) Amounts shall be due at the earliest of the following dates:
(1) The date fixed under this contract.
(2) The date of the first written demand for payment, including any demand for payment resulting from a default termination.
(f) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on—
(1) The date on which the designated office receives payment from the Contractor;
(2) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or
(3) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor.
(g) The interest charge made under this clause may be reduced under the procedures prescribed in 32.608-2 of the Federal Acquisition Regulation in effect on the date of this contract.

I.104  52.232-22 -- Limitation of Funds (Apr 1984)
(a) The parties estimate that performance of this contract will not cost the Government more than
(1) the estimated cost specified in the Schedule or,
(2) if this is a cost-sharing contract, the Government’s share of the estimated cost specified in the Schedule.
The Contractor agrees to use its best efforts to perform the work specified in the Schedule and all obligations under this contract within the estimated cost, which, if this is a cost-sharing contract, includes both the Government’s and the Contractor’s share of the cost.
(b) The Schedule specifies the amount presently available for payment by the Government and allotted to this contract, the items covered, the Government’s share of the cost if this is a cost-sharing contract, and the period of performance it is estimated the allotted amount will cover. The parties contemplate that the Government will allot additional funds incrementally to the contract up to the full estimated cost to the Government specified in the Schedule, exclusive of any fee. The Contractor agrees to perform, or have performed, work on the contract up to the point at which the total amount paid and payable by the Government under the contract approximates but does not exceed the total amount actually allotted by the Government to the contract.
(c) The Contractor shall notify the Contracting Officer in writing whenever it has reason to believe that the costs it expects to incur under this contract in the next 60 days, when added to all costs previously incurred, will exceed 75 percent of
(1) the total amount so far allotted to the contract by the Government or,
(2) if this is a cost-sharing contract, the amount then allotted to the contract by the Government plus the Contractor’s corresponding share.
The notice shall state the estimated amount of additional funds required to continue performance for the period specified in the Schedule.
(d) Sixty days before the end of the period specified in the Schedule, the Contractor shall notify the Contracting Officer in writing of the estimated amount of additional funds, if any, required to continue timely performance under the contract or for any further period specified in the Schedule or otherwise agreed upon, and when the funds will be required.
(e) If, after notification, additional funds are not allotted by the end of the period specified in the Schedule or another agreed-upon date, upon the Contractor’s written request the Contracting Officer will terminate this contract on that date in accordance with the provisions of the Termination clause of this contract. If the Contractor estimates that the funds available will allow it to continue to discharge its obligations beyond that date, it may specify a later date in its request, and the Contracting Officer may terminate this contract on that later date.
(f) Except as required by other provisions of this contract, specifically citing and stated to be an exception to this clause --
(1) The Government is not obligated to reimburse the Contractor for costs incurred in excess of the total amount allotted by the Government to this contract; and
(2) The Contractor is not obligated to continue performance under this contract (including actions under the Termination clause of this contract) or otherwise incur costs in excess of --
(i) The amount then allotted to the contract by the Government or;
(ii) If this is a cost-sharing contract, the amount then allotted by the Government to the contract plus the Contractor’s corresponding share, until the Contracting Officer notifies the Contractor in writing that the amount allotted by the Government has been increased and specifies an increased amount, which shall then constitute the total amount allotted by the Government to this contract.
(g) The estimated cost shall be increased to the extent that
(1) the amount allotted by the Government or,
(2) if this is a cost-sharing contract, the amount then allotted by the Government to the contract plus the Contractor’s corresponding share, exceeds the estimated cost specified in the Schedule.
If this is a cost-sharing contract, the increase shall be allocated in accordance with the formula specified in the Schedule.
(h) No notice, communication, or representation in any form other than that specified in subparagraph (f)(2) above, or from any person other than the Contracting Officer, shall affect the amount allotted by the Government to this contract. In the absence of the specified notice, the Government is not obligated to reimburse the Contractor for any costs in excess of the total amount allotted by the Government to this contract, whether incurred during the course of the contract or as a result of termination.
(i) When and to the extent that the amount allotted by the Government to the contract is increased, any costs the Contractor incurs before the increase that are in excess of --
(1) The amount previously allotted by the Government or;
(2) If this is a cost-sharing contract, the amount previously allotted by the Government to the contract plus the Contractor’s corresponding share, shall be allowable to the same extent as if incurred afterward, unless the Contracting Officer issues a termination or other notice and directs that the increase is solely to cover termination or other specified expenses.
(j) Change orders shall not be considered an authorization to exceed the amount allotted by the Government specified in the Schedule, unless they contain a statement increasing the amount allotted.
(k) Nothing in this clause shall affect the right of the Government to terminate this contract. If this contract is terminated, the Government and the Contractor shall negotiate an equitable distribution of all property produced or purchased under the contract, based upon the share of costs incurred by each.
(l) If the Government does not allot sufficient funds to allow completion of the work, the Contractor is entitled to a percentage of the fee specified in the Schedule equaling the percentage of completion of the work contemplated by this contract.

I.105  52.232-23 -- Assignment of Claims (May 2014)
(a) The Contractor, under the Assignment of Claims Act, as amended, 31 U.S.C. 3727, 41 U.S.C. 6305 (hereafter referred to as “the Act”), may assign its rights to be paid amounts due or to become due as a result of the performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency. The assignee under such an assignment may thereafter further assign or reassign its right under the original assignment to any type of financing institution described in the preceding sentence.
(b) Any assignment or reassignment authorized under the Act and this clause shall cover all unpaid amounts payable under this contract, and shall not be made to more than one party, except that an assignment or reassignment may be made to one party as agent or trustee for two or more parties participating in the financing of this contract.
(c) The Contractor shall not furnish or disclose to any assignee under this contract any classified document (including this contract) or information related to work under this contract until the Contracting Officer authorizes such action in writing.

I.106 52.232-25 -- Prompt Payment (Jan 2017)
Notwithstanding any other payment clause in this contract, the Government will make invoice payments under the terms and conditions specified in this clause. The Government considers payment as being made on the day a check is dated or the date of an electronic funds transfer (EFT). Definitions of pertinent terms are set forth in sections 2.101, 32.001, and 32.902 of the Federal Acquisition Regulation. All days referred to in this clause are calendar days, unless otherwise specified. (However, see subparagraph (a)(4) of this clause concerning payments due on Saturdays, Sundays, and legal holidays.)
(a) Invoice payments --
(1) Due date.
(i) Except as indicated in paragraphs (a)(2) and (c) of this clause, the due date for making invoice payments by the designated payment office shall be the later of the following two events:
(A) The 30th day after the designated billing office receives a proper invoice from the Contractor (except as provided in paragraph (a)(1)(ii) of this clause).
(B) The 30th day after Government acceptance of supplies delivered or services performed. For a final invoice, when the payment amount is subject to contract settlement actions, acceptance is deemed to occur on the effective date of the contract settlement.
(ii) If the designated billing office fails to annotate the invoice with the actual date of receipt at the time of receipt, the invoice payment due date is the 30th day after the date of the Contractor’s invoice; provided the designated billing office receives a proper invoice and there is no disagreement over quantity, quality, or Contractor compliance with contract requirements.
(2) Certain food products and other payments.
(i) Due dates on Contractor invoices for meat, meat food products, or fish; perishable agricultural commodities; and dairy products, edible fats or oils, and food products prepared from edible fats or oils are --
(A) For meat or meat food products, as defined in section 2(a)(3) of the Packers and Stockyard Act of 1921 (7 U.S.C. 182(3)), and as further defined in Pub. L. 98-181, including any edible fresh or frozen poultry meat, any perishable poultry meat food product, fresh eggs, and any perishable egg product, as close as possible to, but not later than, the 7th day after product delivery.
(B) For fresh or frozen fish, as defined in section 204(3) of the Fish and Seafood Promotion Act of 1986 (16 U.S.C. 4003(3)), as close as possible to, but not later than, the 7th day after product delivery.
(C) For perishable agricultural commodities, as defined in section 1(4) of the Perishable Agricultural Commodities Act of 1930 (7 U.S.C. 499a(4)), as close as possible to, but not later than, the 10th day after product delivery, unless another date is specified in the contract.
(D) For dairy products, as defined in section 111(e) of the Dairy Production Stabilization Act of 1983 (7 U.S.C. 4502(e)), edible fats or oils, and food products prepared from edible fats or oils, as close as possible to, but not later than, the 10th day after the date on which a proper invoice has been received. Liquid milk, cheese, certain processed cheese products, butter, yogurt, ice cream, mayonnaise, salad dressings, and other similar products, fall within this classification. Nothing in the Act limits this classification to refrigerated products. When questions arise regarding the proper classification of a specific product, prevailing industry practices will be followed in specifying a contract payment due date. The burden of proof that a classification of a specific product is, in fact, prevailing industry practice is upon the Contractor making the representation.
(ii) If the contract does not require submission of an invoice for payment (e.g., periodic lease payments), the due date will be as specified in the contract.
(3) Contractor’s invoice. The Contractor shall prepare and submit invoices to the designated billing office specified in the contract. A proper invoice must include the items listed in paragraphs (a)(3)(i) through (a)(3)(x) of this clause. If the invoice does not comply with these requirements, the designated billing office will return it within 7 days after receipt (3 days for meat, meat food products, or fish; 5 days for perishable agricultural commodities, dairy products, edible fats or oils, and food products prepared from edible fats or oils), with the reasons why it is not a proper invoice. The Government will take into account untimely notification when computing any interest penalty owed the Contractor.
(i) Name and address of the Contractor.
(ii) Invoice date and invoice number. (The Contractor should date invoices as close as possible to the date of the mailing or transmission.)
(iii) Contract number or other authorization for supplies delivered or services performed (including order number and line item number).
(iv) Description, quantity, unit of measure, unit price, and extended price of supplies delivered or services performed.
(v) Shipping and payment terms (e.g., shipment number and date of shipment, discount for prompt payment terms). Bill of lading number and weight of shipment will be shown for shipments on Government bills of lading.
(vi) Name and address of Contractor official to whom payment is to be sent (must be the same as that in the contract or in a proper notice of assignment).
(vii) Name (where practicable), title, phone number, and mailing address of person to notify in the event of a defective invoice.
(viii) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract.
(ix) Electronic funds transfer (EFT) banking information.
(A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract.
(B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision (e.g., 52.232-38, Submission of Electronic Funds Transfer Information with Offer), contract clause (e.g., 52.232-33, Payment by Electronic funds Transfer— System for Award Management, or 52.232-34, Payment by Electronic Funds Transfer--Other Than System for Award Management), or applicable agency procedures.
(C) EFT banking information is not required if the Government waived the requirement to pay by EFT.
(x) Any other information or documentation required by the contract (e.g.. evidence of shipment.)
(4) Interest penalty. The designated payment office will pay an interest penalty automatically, without request from the Contractor, if payment is not made by the due date and the conditions listed in paragraphs (a)(4)(i) through (a)(4)(iii) of this clause are met, if applicable. However, when the due date falls on a Saturday, Sunday, or legal holiday, the designated payment office may make payment on the following working day without incurring a late payment interest penalty.
(i) The designated billing office received a proper invoice.
(ii) The Government processed a receiving report or other Government documentation authorizing payment, and there was no disagreement over quantity, quality, or Contractor compliance with any contract term or condition.
(iii) In the case of a final invoice for any balance of funds due the Contractor for supplies delivered or services performed, the amount was not subject to further contract settlement actions between the Government and the Contractor.
(5) Computing penalty amount. The Government will compute the interest penalty in accordance with Office of Management and Budget prompt payment regulations at 5 CFR part 1315. 
(i) For the sole purpose of computing an interest penalty that might be due the Contractor, Government acceptance is deemed to occur constructively on the 7th day (unless otherwise specified in this contract) after the Contractor delivers the supplies or performs the services in accordance with the terms and conditions of the contract, unless there is a disagreement over quantity, quality, or Contractor compliance with a contract provision. If actual acceptance occurs within the constructive acceptance period, the Government will base the determination of an interest penalty on the actual date of acceptance. The constructive acceptance requirement does not, however, compel Government officials to accept supplies or services, perform contract administration functions, or make payment prior to fulfilling their responsibilities.
(ii) The prompt payment regulations at 5 CFR 1315.10(c) do not require the Government to pay interest penalties if payment delays are due to disagreement between the Government and the Contractor over the payment amount or other issues involving contract compliance, or on amounts temporarily withheld or retained in accordance with the terms of the contract. The Government and the Contractor shall resolve claims involving disputes and any interest that may be payable in accordance with the clause at FAR 52.233-1, Disputes.
(6) Discounts for prompt payment. The designated payment office will pay an interest penalty automatically, without request from the Contractor, if the Government takes a discount for prompt payment improperly. The Government will calculate the interest penalty in accordance with the prompt payment regulations at 5 CFR part 1315.
(7) Additional interest penalty.
(i) The designated payment office will pay a penalty amount, calculated in accordance with the prompt payment regulations at 5 CFR part 1315 in addition to the interest penalty amount only if--
(A) The Government owes an interest penalty of $1 or more;
(B) The designated payment office does not pay the interest penalty within 10 days after the date the invoice amount is paid; and
(C) The Contractor makes a written demand to the designated payment office for additional penalty payment, in accordance with paragraph (a)(7)(ii) of this clause, postmarked not later than 40 days after the invoice amount is paid.
(ii)
(A) The Contractor shall support written demands for additional penalty payments with the following data. The Government will not request any additional data. The Contractor shall --
(1) Specifically assert that late payment interest is due under a specific invoice, and request payment of all overdue late payment interest penalty and such additional penalty as may be required;
(2) Attach a copy of the invoice on which the unpaid late payment interest was due; and
(3) State that payment of the principal has been received, including the date of receipt.
(B) If there is no postmark or the postmark is illegible--
(1) The designated payment office that receives the demand will annotate it with the date of receipt, provided the demand is received on or before the 40th day after payment was made; or
(2) If the designated payment office fails to make the required annotation, the Government will determine the demand’s validity based on the date the Contractor has placed on the demand; provided such date is no later than the 40th day after payment was made.
(iii) The additional penalty does not apply to payments regulated by other Government regulations (e.g., payments under utility contracts subject to tariffs and regulation).
(b) Contract financing payments. If this contract provides for contract financing, the Government will make contract financing payments in accordance with the applicable contract financing clause.
(c) Fast payment procedure due dates. If this contract contains the clause at 52.213-1, Fast Payment Procedure, payments will be made within 15 days after the date of receipt of the invoice.
(d) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall—
(1) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the—
(i) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment);
(ii) Affected contract number and delivery order number if applicable;
(iii) Affected line item or subline item, if applicable; and
(iv) Contractor point of contact.
(2) Provide a copy of the remittance and supporting documentation to the Contracting Officer.
 (e) Invoices for interim payments. For interim payments under this cost-reimbursement contract for services--
(1) Paragraphs (a)(2,), (a)(3), (a)(4(ii), (a)(4(iii), and (a)(5)(i) do not apply;
(2) For purposes of computing late payment interest penalties that may apply, the due date for payment is the 30th day after the designated billing office receives a proper invoice; and
(3) The Contractor shall submit invoices for interim payments in accordance with paragraph (a) of FAR 52.216-7, Allowable Cost and Payment. If the invoice does not comply with contract requirements, it will be returned within 7 days after the date the designated billing office received the invoice.

I.107  52.232-33 -- Payment by Electronic Funds Transfer-- System for Award Management (Oct 2018)
(a) Method of payment. 
(1) All payments by the Government under this contract, shall be made by electronic funds transfer (EFT), except as provided in paragraph (a)(2) of this clause. As used in this clause, the term “EFT” refers to the funds transfer and may also include the payment information transfer.
(2) In the event the Government is unable to release one or more payments by EFT, the Contractor agrees to either--
(i) Accept payment by check or some other mutually agreeable method of payment; or
(ii) Request the Government to extend the payment due date until such time as the Government can make payment by EFT (but see paragraph (d) of this clause).
(b) Contractor's EFT information. The Government shall make payment to the Contractor using the EFT information contained in the System for Award Management (SAM). In the event that the EFT information changes, the Contractor shall be responsible for providing the updated information to the SAM.
(c) Mechanisms for EFT payment. The Government may make payment by EFT through either the Automated Clearing House (ACH) network, subject to the rules of the National Automated Clearing House Association, or the Fedwire Transfer System. The rules governing Federal payments through the ACH are contained in 31 CFR part 210.
(d) Suspension of payment. If the Contractor's EFT information in the SAM is incorrect, then the Government need not make payment to the Contractor under this contract until correct EFT information is entered into the SAM; and any invoice or contract financing request shall be deemed not to be a proper invoice for the purpose of prompt payment under this contract. The prompt payment terms of the contract regarding notice of an improper invoice and delays in accrual of interest penalties apply. 
(e) Liability for uncompleted or erroneous transfers.
(1) If an uncompleted or erroneous transfer occurs because the Government used the Contractor's EFT information incorrectly, the Government remains responsible for--
(i) Making a correct payment;
(ii) Paying any prompt payment penalty due; and
(iii) Recovering any erroneously directed funds.
(2) If an uncompleted or erroneous transfer occurs because the Contractor's EFT information was incorrect, or was revised within 30 days of Government release of the EFT payment transaction instruction to the Federal Reserve System, and--
(i) If the funds are no longer under the control of the payment office, the Government is deemed to have made payment and the Contractor is responsible for recovery of any erroneously directed funds; or
(ii) If the funds remain under the control of the payment office, the Government shall not make payment, and the provisions of paragraph (d) of this clause shall apply.
(f) EFT and prompt payment. A payment shall be deemed to have been made in a timely manner in accordance with the prompt payment terms of this contract if, in the EFT payment transaction instruction released to the Federal Reserve System, the date specified for settlement of the payment is on or before the prompt payment due date, provided the specified payment date is a valid date under the rules of the Federal Reserve System.
(g) EFT and assignment of claims. If the Contractor assigns the proceeds of this contract as provided for in the assignment of claims terms of this contract, the Contractor shall require as a condition of any such assignment, that the assignee shall register separately in the SAM and shall be paid by EFT in accordance with the terms of this clause. Notwithstanding any other requirement of this contract, payment to an ultimate recipient other than the Contractor, or a financial institution properly recognized under an assignment of claims pursuant to Subpart 32.8, is not permitted. In all respects, the requirements of this clause shall apply to the assignee as if it were the Contractor. EFT information that shows the ultimate recipient of the transfer to be other than the Contractor, in the absence of a proper assignment of claims acceptable to the Government, is incorrect EFT information within the meaning of paragraph (d) of this clause.
(h) Liability for change of EFT information by financial agent. The Government is not liable for errors resulting from changes to EFT information made by the Contractor's financial agent.
(i) Payment information. The payment or disbursing office shall forward to the Contractor available payment information that is suitable for transmission as of the date of release of the EFT instruction to the Federal Reserve System. The Government may request the Contractor to designate a desired format and method(s) for delivery of payment information from a list of formats and methods the payment office is capable of executing. However, the Government does not guarantee that any particular format or method of delivery is available at any particular payment office and retains the latitude to use the format and delivery method most convenient to the Government. If the Government makes payment by check in accordance with paragraph (a) of this clause, the Government shall mail the payment information to the remittance address contained in the SAM.

I.108  52.232-39 – Unenforceability of Unauthorized Obligations (Jun 2013)
(a) Except as stated in paragraph (b) of this clause, when any supply or service acquired under this contract is subject to any End User License Agreement (EULA), Terms of Service (TOS), or similar legal instrument or agreement , that includes any clause requiring the Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C. 1341), the following shall govern:
(1) Any such clause is unenforceable against the Government.
(2) Neither the Government nor any Government authorized end user shall be deemed to have agreed to such clause by virtue of it appearing in the EULA, TOS, or similar legal instrument or agreement. If the EULA, TOS, or similar legal instrument or agreement is invoked through an “I agree” click box or other comparable mechanism (e.g., “click-wrap” or “browse-wrap” agreements), execution does not bind the Government or any Government authorized end user to such clause.
(3) Any such clause is deemed to be stricken from the EULA, TOS, or similar legal instrument or agreement.
(b) Paragraph (a) of this clause does not apply to indemnification by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulation and procedures.

I.109  52.232-40 – Providing Accelerated Payments to Small Business Subcontractors (Dec 2013)
(a) Upon receipt of accelerated payments from the Government, the Contractor shall make accelerated payments to its small business subcontractors under this contract, to the maximum extent practicable and prior to when such payment is otherwise required under the applicable contract or subcontract, after receipt of a proper invoice and all other required documentation from the small business subcontractor.
(b) The acceleration of payments under this clause does not provide any new rights under the Prompt Payment Act.
(c) Include the substance of this clause, including this paragraph (c), in all subcontracts with small business concerns, including subcontracts with small business concerns for the acquisition of commercial items.

I.110  52.233-1 -- Disputes (May 2014)
(a) This contract is subject to 41 U.S.C. chapter 71, Contract Disputes.
(b) Except as provided in 41 U.S.C. chapter 71, all disputes arising under or relating to this contract shall be resolved under this clause.
(c) “Claim,” as used in this clause, means a written demand or written assertion by one of the contracting parties seeking, as a matter of right, the payment of money in a sum certain, the adjustment or interpretation of contract terms, or other relief arising under or relating to this contract. However, a written demand or written assertion by the Contractor seeking the payment of money exceeding $100,000 is not a claim under 41 U.S.C. chapter 71 until certified. A voucher, invoice, or other routine request for payment that is not in dispute when submitted is not a claim under 41 U.S.C. chapter 71. The submission may be converted to a claim under 41 U.S.C. chapter 71, by complying with the submission and certification requirements of this clause, if it is disputed either as to liability or amount or is not acted upon in a reasonable time.
(d)
(1) A claim by the Contractor shall be made in writing and, unless otherwise stated in this contract, submitted within 6 years after accrual of the claim to the Contracting Officer for a written decision. A claim by the Government against the Contractor shall be subject to a written decision by the Contracting Officer.
(2)
(i) The contractor shall provide the certification specified in paragraph (d)(2)(iii) of this clause when submitting any claim exceeding $100,000.
(ii) The certification requirement does not apply to issues in controversy that have not been submitted as all or part of a claim.
(iii) The certification shall state as follows: “I certify that the claim is made in good faith; that the supporting data are accurate and complete to the best of my knowledge and belief; that the amount requested accurately reflects the contract adjustment for which the Contractor believes the Government is liable; and that I am authorized to certify the claim on behalf of the Contractor.”
(3) The certification may be executed by any person authorized to bind the Contractor with respect to the claim.
(e) For Contractor claims of $100,000 or less, the Contracting Officer must, if requested in writing by the Contractor, render a decision within 60 days of the request. For Contractor-certified claims over $100,000, the Contracting Officer must, within 60 days, decide the claim or notify the Contractor of the date by which the decision will be made.
(f) The Contracting Officer’s decision shall be final unless the Contractor appeals or files a suit as provided in 41 U.S.C. chapter 71.
(g) If the claim by the Contractor is submitted to the Contracting Officer or a claim by the Government is presented to the Contractor, the parties, by mutual consent, may agree to use alternative dispute resolution (ADR). If the Contractor refuses an offer for ADR, the Contractor shall inform the Contracting Officer, in writing, of the Contractor’s specific reasons for rejecting the offer.
(h) The Government shall pay interest on the amount found due and unpaid from
(1) the date that the Contracting Officer receives the claim (certified, if required); or
(2) the date that payment otherwise would be due, if that date is later, until the date of payment.
With regard to claims having defective certifications, as defined in FAR 33.201, interest shall be paid from the date that the Contracting Officer initially receives the claim. Simple interest on claims shall be paid at the rate, fixed by the Secretary of the Treasury as provided in the Act, which is applicable to the period during which the Contracting Officer receives the claim and then at the rate applicable for each 6-month period as fixed by the Treasury Secretary during the pendency of the claim.
(i) The Contractor shall proceed diligently with performance of this contract, pending final resolution of any request for relief, claim, appeal, or action arising under or relating to the contract, and comply with any decision of the Contracting Officer.

I.111  52.233-3 -- Protest After Award (Aug. 1996)
(a) Upon receipt of a notice of protest (as defined in FAR 33.101) or a determination that a protest is likely (see FAR 33.102(d)), the Contracting Officer may, by written order to the Contractor, direct the Contractor to stop performance of the work called for by this contract. The order shall be specifically identified as a stop-work order issued under this clause. Upon receipt of the order, the Contractor shall immediately comply with its terms and take all reasonable steps to minimize the incurrence of costs allocable to the work covered by the order during the period of work stoppage. Upon receipt of the final decision in the protest, the Contracting Officer shall either --
(1) Cancel the stop-work order; or
(2) Terminate the work covered by the order as provided in the Default, or the Termination for Convenience of the Government, clause of this contract.
(b) If a stop-work order issued under this clause is canceled either before or after a final decision in the protest, the Contractor shall resume work. The Contracting Officer shall make an equitable adjustment in the delivery schedule or contract price, or both, and the contract shall be modified, in writing, accordingly, if --
(1) The stop-work order results in an increase in the time required for, or in the Contractor’s cost properly allocable to, the performance of any part of this contract; and
(2) The Contractor asserts its right to an adjustment within 30 days after the end of the period of work stoppage; provided, that if the Contracting Officer decides the facts justify the action, the Contracting Officer may receive and act upon a proposal at any time before final payment under this contract.
(c) If a stop-work order is not canceled and the work covered by the order is terminated for the convenience of the Government, the Contracting Officer shall allow reasonable costs resulting from the stop-work order in arriving at the termination settlement.
(d) If a stop-work order is not canceled and the work covered by the order is terminated for default, the Contracting Officer shall allow, by equitable adjustment or otherwise, reasonable costs resulting from the stop-work order.
(e) The Government’s rights to terminate this contract at any time are not affected by action taken under this clause.
(f) If, as the result of the Contractor’s intentional or negligent misstatement, misrepresentation, or miscertification, a protest related to this contract is sustained, and the Government pays costs, as provided in FAR 33.102(b)(2) or 33.104(h)(1), the Government may require the Contractor to reimburse the Government the amount of such costs. In addition to any other remedy available, and pursuant to the requirements of Subpart 32.6, the Government may collect this debt by offsetting the amount against any payment due the Contractor under any contract between the Contractor and the Government.

I.112  52.233-4 -- Applicable Law for Breach of Contract Claim (OCT 2004)
United States law will apply to resolve any claim of breach of this contract.

I.113  52.236-5 -- Material and Workmanship (Apr 1984)
(a) All equipment, material, and articles incorporated into the work covered by this contract shall be new and of the most suitable grade for the purpose intended, unless otherwise specifically provided in this contract. References in the specifications to equipment, material, articles, or patented processes by trade name, make, or catalog number, shall be regarded as establishing a standard of quality and shall not be construed as limiting competition. The Contractor may, at its option, use any equipment, material, article, or process that, in the judgment of the Contracting Officer, is equal to that named in the specifications, unless otherwise specifically provided in this contract.
(b) The Contractor shall obtain the Contracting Officer’s approval of the machinery and mechanical and other equipment to be incorporated into the work. When requesting approval, the Contractor shall furnish to the Contracting Officer the name of the manufacturer, the model number, and other information concerning the performance, capacity, nature, and rating of the machinery and mechanical and other equipment. When required by this contract or by the Contracting Officer, the Contractor shall also obtain the Contracting Officer’s approval of the material or articles which the Contractor contemplates incorporating into the work. When requesting approval, the Contractor shall provide full information concerning the material or articles. When directed to do so, the Contractor shall submit samples for approval at the Contractor’s expense, with all shipping charges prepaid. Machinery, equipment, material, and articles that do not have the required approval shall be installed or used at the risk of subsequent rejection.
(c) All work under this contract shall be performed in a skillful and workmanlike manner. The Contracting Officer may require, in writing, that the Contractor remove from the work any employee the Contracting Officer deems incompetent, careless, or otherwise objectionable.

I.114  52.239-1 -- Privacy or Security Safeguards (Aug. 1996)
(a) The Contractor shall not publish or disclose in any manner, without the Contracting Officer’s written consent, the details of any safeguards either designed or developed by the Contractor under this contract or otherwise provided by the Government.
(b) To the extent required to carry out a program of inspection to safeguard against threats and hazards to the security, integrity, and confidentiality of Government data, the Contractor shall afford the Government access to the Contractor’s facilities, installations, technical capabilities, operations, documentation, records, and databases.
(c) If new or unanticipated threats or hazards are discovered by either the Government or the Contractor, or if existing safeguards have ceased to function, the discoverer shall immediately bring the situation to the attention of the other party.

I.115  52.242-1 -- Notice of Intent to Disallow Costs (Apr 1984)
(a) Notwithstanding any other clause of this contract --
(1) The Contracting Officer may at any time issue to the Contractor a written notice of intent to disallow specified costs incurred or planned for incurrence under this contract that have been determined not to be allowable under the contract terms; and
(2) The Contractor may, after receiving a notice under subparagraph (1) above, submit a written response to the Contracting Officer, with justification for allowance of the costs. If the Contractor does respond within 60 days, the Contracting Officer shall, within 60 days of receiving the response, either make a written withdrawal of the notice or issue a written decision.
(b) Failure to issue a notice under this Notice of Intent to Disallow Costs clause shall not affect the Government’s rights to take exception to incurred costs.

I.116  52.242-3 -- Penalties for Unallowable Costs (May 2014)
(a) Definition. “Proposal,” as used in this clause, means either --
(1) A final indirect cost rate proposal submitted by the Contractor after the expiration of its fiscal year which --
(i) Relates to any payment made on the basis of billing rates; or 
(ii) Will be used in negotiating the final contract price; or
(2) The final statement of costs incurred and estimated to be incurred under the Incentive Price Revision clause (if applicable), which is used to establish the final contract price.
(b) Contractors which include unallowable indirect costs in a proposal may be subject to penalties. The penalties are prescribed in 10 U.S.C. 2324 or 41 U.S.C. chapter 43, as applicable, which is implemented in Section 42.709 of the Federal Acquisition Regulation (FAR).
(c) The Contractor shall not include in any proposal any cost that is unallowable, as defined in Subpart 2.1 of the FAR, or an executive agency supplement to the FAR.
(d) If the Contracting Officer determines that a cost submitted by the Contractor in its proposal is expressly unallowable under a cost principle in the FAR, or an executive agency supplement to the FAR, that defines the allowability of specific selected costs, the Contractor shall be assessed a penalty equal to --
(1) The amount of the disallowed cost allocated to this contract; plus 
(2) Simple interest, to be computed --
(i) On the amount the Contractor was paid (whether as a progress or billing payment) in excess of the amount to which the Contractor was entitled; and
(ii) Using the applicable rate effective for each six-month interval prescribed by the Secretary of the Treasury pursuant to Pub. L. 92-41 (85 Stat. 97).
(e) If the Contracting Officer determines that a cost submitted by the Contractor in its proposal includes a cost previously determined to be unallowable for that Contractor, then the Contractor will be assessed a penalty in an amount equal to two times the amount of the disallowed cost allocated to this contract.
(f) Determinations under paragraphs (d) and (e) of this clause are final decisions within the meaning of 41 U.S.C. chapter 71, Contract Disputes.
(g) Pursuant to the criteria in FAR 42.709-5, the Contracting Officer may waive the penalties in paragraph (d) or (e) of this clause.
(h) Payment by the Contractor of any penalty assessed under this clause does not constitute repayment to the Government of any unallowable cost which has been paid by the Government to the Contractor.

I.117  52.242-4 -- Certification of Final Indirect Costs (Jan 1997)
(a) The Contractor shall --
(1) Certify any proposal to establish or modify final indirect cost rates;
(2) Use the format in paragraph (c) of this clause to certify; and
(3) Have the certificate signed by an individual of the Contractor’s organization at a level no lower than a vice president or chief financial officer of the business segment of the Contractor that submits the proposal.
(b) Failure by the Contractor to submit a signed certificate, as described in this clause, may result in final indirect costs at rates unilaterally established by the Contracting Officer.
(c) The certificate of final indirect costs shall read as follows:
Certificate of Final Indirect Costs
This is to certify that I have reviewed this proposal to establish final indirect cost rates and to the best of my knowledge and belief:
1. All costs included in this proposal (identify proposal and date) to establish final indirect cost rates for (identify period covered by rate) are allowable in accordance with the cost principles of the Federal Acquisition Regulation (FAR) and its supplements applicable to the contracts to which the final indirect cost rates will apply; and
2. This proposal does not include any costs which are expressly unallowable under applicable cost principles of the FAR or its supplements.
Firm: _____________________________________ 
 
Signature: _________________________________ 
 
Name of Certifying Official: __________________ 
 
Title: _____________________________________ 
 
Date of Execution: __________________________

I.118  52.242-13 -- Bankruptcy (Jul 1995)
In the event the Contractor enters into proceedings relating to bankruptcy, whether voluntary or involuntary, the Contractor agrees to furnish, by certified mail or electronic commerce method authorized by the contract, written notification of the bankruptcy to the Contracting Officer responsible for administering the contract. This notification shall be furnished within five days of the initiation of the proceedings relating to bankruptcy filing. This notification shall include the date on which the bankruptcy petition was filed, the identity of the court in which the bankruptcy petition was filed, and a listing of Government contract numbers and contracting offices for all Government contracts against which final payment has not been made. This obligation remains in effect until final payment of the contract. 

I.119  52.243-2 -- Changes -- Cost-Reimbursement (Aug 1987) (Alt I)
(a) The Contracting Officer may at any time, by written order, and without notice to the sureties, if any, make changes within the general scope of this contract in any one or more of the following:
(1) Description of services to be performed.
(2) Time of performance (i.e., hours of the day, days of the week, etc.).
(3) Place of performance of the services.
(4) Drawings, designs, or specifications when the supplies to be furnished are to be specially manufactured for the Government in accordance with the drawings, designs, or specifications.
(5) Method of shipment or packing of supplies.
(6) Place of delivery.
 (b) If any such change causes an increase or decrease in the estimated cost of, or the time required for, performance of any part of the work under this contract, whether or not changed by the order, or otherwise affects any other terms and conditions of this contract, the Contracting Officer shall make an equitable adjustment in the --
(1) Estimated cost, delivery or completion schedule, or both;
(2) Amount of any fixed fee; and
(3) Other affected terms and shall modify the contract accordingly.
(c) The Contractor must assert its right to an adjustment under this clause within 30 days from the date of receipt of the written order. However, if the Contracting Officer decides that the facts justify it, the Contracting Officer may receive and act upon a proposal submitted before final payment of the contract.
(d) Failure to agree to any adjustment shall be a dispute under the Disputes clause. However, nothing in this clause shall excuse the Contractor from proceeding with the contract as changed.
(e) Notwithstanding the terms and conditions of paragraphs (a) and (b) above, the estimated cost of this contract and, if this contract is incrementally funded, the funds allotted for the performance of this contract, shall not be increased or considered to be increased except by specific written modification of the contract indicating the new contract estimated cost and, if this contract is incrementally funded, the new amount allotted to the contract. Until this modification is made, the Contractor shall not be obligated to continue performance or incur costs beyond the point established in the Limitation of Cost or Limitation of Funds clause of this contract.

I.120  52.243-6 -- Change Order Accounting (Apr 1984)
The Contracting Officer may require change order accounting whenever the estimated cost of a change or series of related changes exceeds $100,000. The Contractor, for each change or series of related changes, shall maintain separate accounts, by job order or other suitable accounting procedure, of all incurred segregable, direct costs (less allocable credits) of work, both changed and not changed, allocable to the change. The Contractor shall maintain such accounts until the parties agree to an equitable adjustment for the changes ordered by the Contracting Officer or the matter is conclusively disposed of in accordance with the Disputes clause.

I.121  52.243-7 -- Notification of Changes (Jan 2017)
(a) Definitions. “Contracting Officer,” as used in this clause, does not include any representative of the Contracting Officer.
“Specifically Authorized Representative (SAR),” as used in this clause, means any person the Contracting Officer has so designated by written notice (a copy of which shall be provided to the Contractor) which shall refer to this subparagraph and shall be issued to the designated representative before the SAR exercises such authority.
(b) Notice. The primary purpose of this clause is to obtain prompt reporting of Government conduct that the Contractor considers to constitute a change to this contract. Except for changes identified as such in writing and signed by the Contracting Officer, the Contractor shall notify the Administrative Contracting Officer in writing promptly, within ____ (to be negotiated) calendar days from the date that the Contractor identifies any Government conduct (including actions, inactions, and written or oral communications) that the Contractor regards as a change to the contract terms and conditions. On the basis of the most accurate information available to the Contractor, the notice shall state --
(1) The date, nature, and circumstances of the conduct regarded as a change;
(2) The name, function, and activity of each Government individual and Contractor official or employee involved in or knowledgeable about such conduct;
(3) The identification of any documents and the substance of any oral communication involved in such conduct;
(4) In the instance of alleged acceleration of scheduled performance or delivery, the basis upon which it arose;
(5) The particular elements of contract performance for which the Contractor may seek an equitable adjustment under this clause, including --
(i) What line items have been or may be affected by the alleged change;
(ii) What labor or materials or both have been or may be added, deleted, or wasted by the alleged change;
(iii) To the extent practicable, what delay and disruption in the manner and sequence of performance and effect on continued performance have been or may be caused by the alleged change;
(iv) What adjustments to contract price, delivery schedule, and other provisions affected by the alleged change are estimated; and
(6) The Contractor’s estimate of the time by which the Government must respond to the Contractor’s notice to minimize cost, delay or disruption of performance.
(c) Continued performance. Following submission of the notice required by paragraph (b) of this clause, the Contractor shall diligently continue performance of this contract to the maximum extent possible in accordance with its terms and conditions as construed by the Contractor, unless the notice reports a direction of the Contracting Officer or a communication from a SAR of the Contracting Officer, in either of which events the Contractor shall continue performance; provided, however, that if the Contractor regards the direction or communication as a change as described in paragraph (b) of this clause, notice shall be given in the manner provided. All directions, communications, interpretations, orders and similar actions of the SAR shall be reduced to writing promptly and copies furnished to the Contractor and to the Contracting Officer. The Contracting Officer shall promptly countermand any action which exceeds the authority of the SAR.
(d) Government response. The Contracting Officer shall promptly, within _____ (to be negotiated) calendar days after receipt of notice, respond to the notice in writing. In responding, the Contracting Officer shall either --
(1) Confirm that the conduct of which the Contractor gave notice constitutes a change and when necessary direct the mode of further performance;
(2) Countermand any communication regarded as a change;
(3) Deny that the conduct of which the Contractor gave notice constitutes a change and when necessary direct the mode of further performance; or
(4) In the event the Contractor’s notice information is inadequate to make a decision under subparagraphs (d)(1), (2), or (3) of this clause, advise the Contractor what additional information is required, and establish the date by which it should be furnished and the date thereafter by which the Government will respond.
(e) Equitable adjustments.
(1) If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or decrease in the Contractor’s cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made --
(i) In the contract price or delivery schedule or both; and
(ii) In such other provisions of the contract as may be affected.
(2) The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor’s failure to provide notice or to continue performance as provided, respectively, in paragraphs (b) and (c) of this clause.
NOTE: The phrases “contract price” and “cost” wherever they appear in the clause, may be appropriately modified to apply to cost-reimbursement or incentive contracts, or to combinations thereof.

I.122  52.244-2 -- Subcontracts (Oct 2010)
(a) Definitions. As used in this clause—
“Approved purchasing system” means a Contractor’s purchasing system that has been reviewed and approved in accordance with Part 44 of the Federal Acquisition Regulation (FAR)
“Consent to subcontract” means the Contracting Officer’s written consent for the Contractor to enter into a particular subcontract.
“Subcontract” means any contract, as defined in FAR Subpart 2.1, entered into by a subcontractor to furnish supplies or services for performance of the prime contract or a subcontract. It includes, but is not limited to, purchase orders, and changes and modifications to purchase orders.
(b) When this clause is included in a fixed-price type contract, consent to subcontract is required only on unpriced contract actions (including unpriced modifications or unpriced delivery orders), and only if required in accordance with paragraph (c) or (d) of this clause.
(c) If the Contractor does not have an approved purchasing system, consent to subcontract is required for any subcontract that-
(1) Is of the cost-reimbursement, time-and-materials, or labor-hour type; or
(2) Is fixed-price and exceeds—
(i) For a contract awarded by the Department of Defense, the Coast Guard, or the National Aeronautics and Space Administration, the greater of the simplified acquisition threshold or 5 percent of the total estimated cost of the contract; or
(ii) For a contract awarded by a civilian agency other than the Coast Guard and the National Aeronautics and Space Administration, either the simplified acquisition threshold or 5 percent of the total estimated cost of the contract.
(d) If the Contractor has an approved purchasing system, the Contractor nevertheless shall obtain the Contracting Officer’s written consent before placing the following subcontracts:
None
(e)(1) The Contractor shall notify the Contracting Officer reasonably in advance of placing any subcontract or modification thereof for which consent is required under paragraph (b), (c), or (d) of this clause, including the following information: 
(i) A description of the supplies or services to be subcontracted.
(ii) Identification of the type of subcontract to be used.
(iii) Identification of the proposed subcontractor.
(iv) The proposed subcontract price.
(v) The subcontractor’s current, complete, and accurate certified cost or pricing data and Certificate of Current Cost or Pricing Data, if required by other contract provisions.
(vi) The subcontractor’s Disclosure Statement or Certificate relating to Cost Accounting Standards when such data are required by other provisions of this contract.
(vii) A negotiation memorandum reflecting -
(A) The principal elements of the subcontract price negotiations;
(B) The most significant considerations controlling establishment of initial or revised prices;
(C) The reason certified cost or pricing data were or were not required;
(D) The extent, if any, to which the Contractor did not rely on the subcontractor’s certified cost or pricing data in determining the price objective and in negotiating the final price;
(E) The extent to which it was recognized in the negotiation that the subcontractor’s certified cost or pricing data were not accurate, complete, or current; the action taken by the Contractor and the subcontractor; and the effect of any such defective data on the total price negotiated;
(F) The reasons for any significant difference between the Contractor’s price objective and the price negotiated; and
(G) A complete explanation of the incentive fee or profit plan when incentives are used. The explanation shall identify each critical performance element, management decisions used to quantify each incentive element, reasons for the incentives, and a summary of all trade-off possibilities considered.
(2) The Contractor is not required to notify the Contracting Officer in advance of entering into any subcontract for which consent is not required under paragraph (b), (c), or (d) of this clause.
(f) Unless the consent or approval specifically provides otherwise, neither consent by the Contracting Officer to any subcontract nor approval of the Contractor’s purchasing system shall constitute a determination -
(1) Of the acceptability of any subcontract terms or conditions; 
(2) Of the allowability of any cost under this contract; or 
(3) To relieve the Contractor of any responsibility for performing this contract.
(g) No subcontract or modification thereof placed under this contract shall provide for payment on a cost-plus-a-percentage-of-cost basis, and any fee payable under cost-reimbursement type subcontracts shall not exceed the fee limitations in FAR 15.404-4(c)(4)(i).
(h) The Contractor shall give the Contracting Officer immediate written notice of any action or suit filed and prompt notice of any claim made against the Contractor by any subcontractor or vendor that, in the opinion of the Contractor, may result in litigation related in any way to this contract, with respect to which the Contractor may be entitled to reimbursement from the Government.
(i) The Government reserves the right to review the Contractor’s purchasing system as set forth in FAR Subpart 44.3.
(j) Paragraphs (c) and (e) of this clause do not apply to the following subcontracts, which were evaluated during negotiations: [CO fill in at definitization]

I.123 52.244-5 -- Competition in Subcontracting (Dec 1996)
(a) The Contractor shall select subcontractors (including suppliers) on a competitive basis to the maximum practical extent consistent with the objectives and requirements of the contract.
(b) If the Contractor is an approved mentor under the Department of Defense Pilot Mentor-Protégé Program (Pub. L. 101-510, section 831 as amended), the Contractor may award subcontracts under this contract on a noncompetitive basis to its protégés.

I.124  52.244-6 -- Subcontracts for Commercial Items (Jan 2019)
(a) Definitions. As used in this clause—
“Commercial item and commercially available off-the-shelf item” have the meanings contained Federal Acquisition Regulation 2.101, Definitions.
“Subcontract” includes a transfer of commercial items between divisions, subsidiaries, or affiliates of the Contractor or subcontractor at any tier.
(b) To the maximum extent practicable, the Contractor shall incorporate, and require its subcontractors at all tiers to incorporate, commercial items or nondevelopmental items as components of items to be supplied under this contract.
(c) 
(1) The Contractor shall insert the following clauses in subcontracts for commercial items:
(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509), if the subcontract exceeds $5.5 million and has a performance period of more than 120 days. In altering this clause to identify the appropriate parties, all disclosures of violation of the civil False Claims Act or of Federal criminal law shall be directed to the agency Office of the Inspector General, with a copy to the Contracting Officer.
(ii) 52.203-15, Whistleblower Protections Under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub. L. 111-5), if the subcontract is funded under the Recovery Act.
(iii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017).
(iv) 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (JUN 2016) other than subcontracts for commercially available off-the-shelf items, if flow down is required in accordance with paragraph (c ) of FAR clause 52.204-21.
(v) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (JUL 2018) (Section 1634 of Pub. L. 115-91).
(vi) 52.219-8, Utilization of Small Business Concerns (Oct 2018) (15 U.S.C. 637(d)(2) and (3)), if the subcontract offers further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.
(vii) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).
(viii) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246).
(ix) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212(a));
(x) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).
(xi) 52.222-37, Employments Reports on Veterans (Feb 2016) (38 U.S.C. 4212).
(xii) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496), if flow down is required in accordance with paragraph (f) of FAR clause 52.222-40.
(xiii)
(A) 52.222-50, Combating Trafficking in Persons (Jan 2019) (22 U.S.C. chapter 78 and E.O. 13627).
(B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).
(xiv) 52.222-55, Minimum Wages under Executive Order 13658 (Dec 2015), if flowdown is required in accordance with paragraph (k) of FAR clause 52.222-55. 
(xv) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706), if flow down is required in accordance with paragraph (m) of FAR clause 52.222-62.
(xvi)
(A) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a) if flow down is required in accordance with 52.224-3(f).
(B) Alternate I (JAN 2017) of 52.224-3, if flow down is required in accordance with 52.224-3(f) and the agency specifies that only its agency-provided training is acceptable.
(xvii) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).
(xviii) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Dec 2013), if flow down is required in accordance with paragraph (c) of FAR clause 52.232-40.
(xix) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. App. 1241 and 10 U.S.C. 2631), if flow down is required in accordance with paragraph (d) of FAR clause 52.247-64. 
(2) While not required, the Contractor may flow down to subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.
(d) The Contractor shall include the terms of this clause, including this paragraph (d), in subcontracts awarded under this contract.

I.125  52.245-1 -- Government Property (Jan 2017) 
(a) Definitions. As used in this clause—
“Cannibalize” means to remove parts from Government property for use or for installation on other Government property.
“Contractor-acquired property” means property acquired, fabricated, or otherwise provided by the Contractor for performing a contract, and to which the Government has title.
“Contractor inventory” means—
(1) Any property acquired by and in the possession of a Contractor or subcontractor under a contract for which title is vested in the Government and which exceeds the amounts needed to complete full performance under the entire contract;
(2) Any property that the Government is obligated or has the option to take over under any type of contract, e.g., as a result either of any changes in the specifications or plans thereunder or of the termination of the contract (or subcontract thereunder), before completion of the work, for the convenience or at the option of the Government; and
(3) Government-furnished property that exceeds the amounts needed to complete full performance under the entire contract.
“Contractor's managerial personnel” means the Contractor's directors, officers, managers, superintendents, or equivalent representatives who have supervision or direction of—
(1) All or substantially all of the Contractor's business;
(2) All or substantially all of the Contractor's operation at any one plant or separate location; or
(3) A separate and complete major industrial operation.
“Demilitarization” means rendering a product unusable for, and not restorable to, the purpose for which it was designed or is customarily used.
“Discrepancies incident to shipment” means any differences (e.g., count or condition) between the items documented to have been shipped and items actually received.
“Equipment” means a tangible item that is functionally complete for its intended purpose, durable, nonexpendable, and needed for the performance of a contract. Equipment is not intended for sale, and does not ordinarily lose its identity or become a component part of another article when put into use. Equipment does not include material, real property, special test equipment or special tooling.
“Government-furnished property” means property in the possession of, or directly acquired by, the Government and subsequently furnished to the Contractor for performance of a contract. Government-furnished property includes, but is not limited to, spares and property furnished for repair, maintenance, overhaul, or modification. Government-furnished property also includes contractor-acquired property if the contractor-acquired property is a deliverable under a cost contract when accepted by the Government for continued use under the contract.
“Government property” means all property owned or leased by the Government. Government property includes both Government-furnished and Contractor-acquired property. Government property includes material, equipment, special tooling, special test equipment, and real property. Government property does not include intellectual property and software.
“Loss of Government Property” means unintended, unforeseen or accidental loss, damage or destruction to Government property that reduces the Government’s expected economic benefits of the property. Loss of Government property does not include purposeful destructive testing, obsolescence, normal wear and tear or manufacturing defects. Loss of Government property includes, but is not limited to—
(1) Items that cannot be found after a reasonable search:
(2) Theft:
(3) Damage resulting in unexpected harm to property requiring repair to restore the item to usable condition; or
(4) Destruction resulting from incidents that render the item useless for its intended purpose or beyond economical repair.
“Material” means property that may be consumed or expended during the performance of a contract, component parts of a higher assembly, or items that lose their individual identity through incorporation into an end item. Material does not include equipment, special tooling, special test equipment or real property.
“Nonseverable” means property that cannot be removed after construction or installation without substantial loss of value or damage to the installed property or to the premises where installed.
“Precious metals” means silver, gold, platinum, palladium, iridium, osmium, rhodium, and ruthenium.
“Production scrap” means unusable material resulting from production, engineering, operations and maintenance, repair, and research and development contract activities. Production scrap may have value when re-melted or reprocessed, e.g., textile and metal clippings, borings, and faulty castings and forgings.
“Property” means all tangible property, both real and personal.
“Property Administrator” means an authorized representative of the Contracting Officer appointed in accordance with agency procedures, responsible for administering the contract requirements and obligations relating to Government property in the possession of a Contractor.
“Property records” means the records created and maintained by the contractor in support of its stewardship responsibilities for the management of Government property.
“Provide” means to furnish, as in Government-furnished property, or to acquire, as in contractor-acquired property.
“Real property” See Federal Management Regulation 102-71.20 (41 CFR 102-71.20). 
“Sensitive property” means property potentially dangerous to the public safety or security if stolen, lost, or misplaced, or that shall be subject to exceptional physical security, protection, control, and accountability. Examples include weapons, ammunition, explosives, controlled substances, radioactive materials, hazardous materials or wastes, or precious metals.
“Unit acquisition cost” means—
(1) For Government-furnished property, the dollar value assigned by the Government and identified in the contract; and
(2) For contractor-acquired property, the cost derived from the Contractor’s records that reflect consistently applied generally accepted accounting principles.
(b) Property management. 
(1) The Contractor shall have a system of internal controls to manage (control, use, preserve, protect, repair and maintain) Government property in its possession. The system shall be adequate to satisfy the requirements of this clause. In doing so, the Contractor shall initiate and maintain the processes, systems, procedures, records, and methodologies necessary for effective and efficient control of Government property. The Contractor shall disclose any significant changes to its property management system to the Property Administrator prior to implementation of the changes. The Contractor may employ customary commercial practices, voluntary consensus standards, or industry-leading practices and standards that provide effective and efficient Government property management that are necessary and appropriate for the performance of this contract (except where inconsistent with law or regulation).
(2) The Contractor's responsibility extends from the initial acquisition and receipt of property, through stewardship, custody, and use until formally relieved of responsibility by authorized means, including delivery, consumption, expending, sale (as surplus property), or other disposition, or via a completed investigation, evaluation, and final determination for lost property. This requirement applies to all Government property under the Contractor's accountability, stewardship, possession or control, including its vendors or subcontractors (see paragraph (f)(1)(v) of this clause).
(3) The Contractor shall include the requirements of this clause in all subcontracts under which Government property is acquired or furnished for subcontract performance.
(4) The Contractor shall establish and maintain procedures necessary to assess its property management system effectiveness and shall perform periodic internal reviews, surveillances, self assessments, or audits. Significant findings or results of such reviews and audits pertaining to Government property shall be made available to the Property Administrator.
(c) Use of Government property. 
(1) The Contractor shall use Government property, either furnished or acquired under this contract, only for performing this contract, unless otherwise provided for in this contract or approved by the Contracting Officer.
(2) Modifications or alterations of Government property are prohibited, unless they are—
(i) Reasonable and necessary due to the scope of work under this contract or its terms and conditions;
(ii) Required for normal maintenance; or
(iii) Otherwise authorized by the Contracting Officer.
(3) The Contractor shall not cannibalize Government property unless otherwise provided for in this contract or approved by the Contracting Officer.
(d) Government-furnished property.
(1) The Government shall deliver to the Contractor the Government-furnished property described in this contract. The Government shall furnish related data and information needed for the intended use of the property. The warranties of suitability of use and timely delivery of Government-furnished property do not apply to property acquired or fabricated by the Contractor as contractor-acquired property and subsequently transferred to another contract with this Contractor.
(2) The delivery and/or performance dates specified in this contract are based upon the expectation that the Government-furnished property will be suitable for contract performance and will be delivered to the Contractor by the dates stated in the contract.
(i) If the property is not delivered to the Contractor by the dates stated in the contract, the Contracting Officer shall, upon the Contractor's timely written request, consider an equitable adjustment to the contract.
(ii) In the event property is received by the Contractor, or for Government-furnished property after receipt and installation, in a condition not suitable for its intended use, the Contracting Officer shall, upon the Contractor's timely written request, advise the Contractor on a course of action to remedy the problem. Such action may include repairing, replacing, modifying, returning, or otherwise disposing of the property at the Government's expense. Upon completion of the required action(s), the Contracting Officer shall consider an equitable adjustment to the contract (see also paragraph (f)(1)(ii)(A) of this clause).
(iii) The Government may, at its option, furnish property in an “as-is” condition. The Contractor will be given the opportunity to inspect such property prior to the property being provided. In such cases, the Government makes no warranty with respect to the serviceability and/or suitability of the property for contract performance. Any repairs, replacement, and/or refurbishment shall be at the Contractor's expense.
(3)(i) The Contracting Officer may by written notice, at any time—
(A) Increase or decrease the amount of Government-furnished property under this contract; 
(B) Substitute other Government-furnished property for the property previously furnished, to be furnished, or to be acquired by the Contractor for the Government under this contract; or
(C) Withdraw authority to use property.
(ii) Upon completion of any action(s) under paragraph (d)(3)(i) of this clause, and the Contractor's timely written request, the Contracting Officer shall consider an equitable adjustment to the contract.
(e) Title to Government property.
(1) All Government-furnished property and all property acquired by the Contractor, title to which vests in the Government under this paragraph (collectively referred to as “Government property”), is subject to the provisions of this clause. The Government shall retain title to all Government-furnished property. Title to Government property shall not be affected by its incorporation into or attachment to any property not owned by the Government, nor shall Government property become a fixture or lose its identity as personal property by being attached to any real property.
(2) Title vests in the Government for all property acquired or fabricated by the Contractor in accordance with the financing provisions or other specific requirements for passage of title in the contract. Under fixed price type contracts, in the absence of financing provisions or other specific requirements for passage of title in the contract, the Contractor retains title to all property acquired by the Contractor for use on the contract, except for property identified as a deliverable end item. If a deliverable item is to be retained by the Contractor for use after inspection and acceptance by the Government, it shall be made accountable to the contract through a contract modification listing the item as Government-furnished property.
(3) Title under Cost-Reimbursement or Time-and-Material Contracts or Cost-Reimbursable line items under Fixed-Price contracts.
(i) Title to all property purchased by the Contractor for which the Contractor is entitled to be reimbursed as a direct item of cost under this contract shall pass to and vest in the Government upon the vendor's delivery of such property.
(ii) Title to all other property, the cost of which is reimbursable to the Contractor, shall pass to and vest in the Government upon—
(A) Issuance of the property for use in contract performance;
(B) Commencement of processing of the property for use in contract performance; or
(C) Reimbursement of the cost of the property by the Government, whichever occurs first.
(f) Contractor plans and systems.
(1) Contractors shall establish and implement property management plans, systems, and procedures at the contract, program, site or entity level to enable the following outcomes:
(i) Acquisition of Property. The Contractor shall document that all property was acquired consistent with its engineering, production planning, and property control operations.
(ii) Receipt of Government Property. The Contractor shall receive Government property and document the receipt, record the information necessary to meet the record requirements of paragraph (f)(1)(iii)(A)(1) through (5) of this clause, identify as Government owned in a manner appropriate to the type of property (e.g., stamp, tag, mark, or other identification), and manage any discrepancies incident to shipment.
(A) Government-furnished property. The Contractor shall furnish a written statement to the Property Administrator containing all relevant facts, such as cause or condition and a recommended course(s) of action, if overages, shortages, or damages and/or other discrepancies are discovered upon receipt of Government-furnished property.
(B) Contractor-acquired property. The Contractor shall take all actions necessary to adjust for overages, shortages, damage and/or other discrepancies discovered upon receipt, in shipment of Contractor-acquired property from a vendor or supplier, so as to ensure the proper allocability and allowability of associated costs.
(iii) Records of Government property. The Contractor shall create and maintain records of all Government property accountable to the contract, including Government-furnished and Contractor-acquired property.
(A) Property records shall enable a complete, current, auditable record of all transactions and shall, unless otherwise approved by the Property Administrator, contain the following:
(1) The name, part number and description, National Stock Number (if needed for additional item identification tracking and/or disposition) and other data elements as necessary and required in accordance with the terms and conditions of the contract.
(2) Quantity received (or fabricated), issued, and balance-on-hand.
(3) Unit acquisition cost.
(4) Unique-item identifier or equivalent (if available and necessary for individual item tracking).
(5) Unit of measure.
(6) Accountable contract number or equivalent code designation.
(7) Location.
(8) Disposition.
(9) Posting reference and date of transaction.
(10) Date placed in service (if required in accordance with the terms and conditions of the contract).
(B) Use of a Receipt and Issue System for Government Material. When approved by the Property Administrator, the Contractor may maintain, in lieu of formal property records, a file of appropriately cross-referenced documents evidencing receipt, issue, and use of material that is issued for immediate consumption.
(iv) Physical inventory. The Contractor shall periodically perform, record, and disclose physical inventory results. A final physical inventory shall be performed upon contract completion or termination. The Property Administrator may waive this final inventory requirement, depending on the circumstances (e.g., overall reliability of the Contractor's system or the property is to be transferred to a follow-on contract).
(v) Subcontractor control.
(A) The Contractor shall award subcontracts that clearly identify items to be provided and the extent of any restrictions or limitations on their use. The Contractor shall ensure appropriate flow down of contract terms and conditions (e.g., extent of liability for loss of Government property).
(B) The Contractor shall assure its subcontracts are properly administered and reviews are periodically performed to determine the adequacy of the subcontractor's property management system.
(vi) Reports. The Contractor shall have a process to create and provide reports of discrepancies, loss of Government property, physical inventory results, audits and self-assessments, corrective actions, and other property related reports as directed by the Contracting Officer.
(vii) Relief of stewardship responsibility and liability. The Contractor shall have a process to enable the prompt recognition, investigation, disclosure and reporting of loss of Government property, including losses that occur at subcontractor or alternate site locations.
(A) This process shall include the corrective actions necessary to prevent recurrence.
(B) Unless otherwise directed by the Property Administrator, the Contractor shall investigate and report to the Government all incidents of property loss as soon as the facts become known. Such reports shall, at a minimum, contain the following information:
(1) Date of incident (if known).
(2) The data elements required under paragraph (f)(1)(iii)(A) of this clause.
(3) Quantity.
(4) Accountable contract number.
(5) A statement indicating current or future need.
(6) Unit acquisition cost, or if applicable, estimated sales proceeds, estimated repair or replacement costs.
(7) All known interests in commingled material of which includes Government material.
(8) Cause and corrective action taken or to be taken to prevent recurrence.
(9) A statement that the Government will receive compensation covering the loss of Government property, in the event the Contractor was or will be reimbursed or compensated.
(10) Copies of all supporting documentation.
(11) Last known location.
(12) A statement that the property did or did not contain sensitive, export controlled, hazardous, or toxic material, and that the appropriate agencies and authorities were notified.
(C) Unless the contract provides otherwise, the Contractor shall be relieved of stewardship responsibility and liability for property when—
(1) Such property is consumed or expended, reasonably and properly, or otherwise accounted for, in the performance of the contract, including reasonable inventory adjustments of material as determined by the Property Administrator;
(2) Property Administrator grants relief of responsibility and liability for loss of Government property;
(3) Property is delivered or shipped from the Contractor’s plant, under Government instructions, except when shipment is to a subcontractor or other location of the Contractor; or
(4) Property is disposed of in accordance with paragraphs (j) and (k) of this clause.
(viii) Utilizing Government property. 
(A) The Contractor shall utilize, consume, move, and store Government Property only as authorized under this contract. The Contractor shall promptly disclose and report Government property in its possession that is excess to contract performance.
(B) Unless otherwise authorized in this contract or by the Property Administrator the Contractor shall not commingle Government material with material not owned by the Government.
(ix) Maintenance. The Contractor shall properly maintain Government property. The Contractor's maintenance program shall enable the identification, disclosure, and performance of normal and routine preventative maintenance and repair. The Contractor shall disclose and report to the Property Administrator the need for replacement and/or capital rehabilitation.
(x) Property closeout. The Contractor shall promptly perform and report to the Property Administrator contract property closeout, to include reporting, investigating and securing closure of all loss of Government property cases; physically inventorying all property upon termination or completion of this contract; and disposing of items at the time they are determined to be excess to contractual needs.
(2) The Contractor shall establish and maintain Government accounting source data, as may be required by this contract, particularly in the areas of recognition of acquisitions, loss of Government property, and disposition of material and equipment.
(g) Systems analysis.
(1) The Government shall have access to the contractor's premises and all Government property, at reasonable times, for the purposes of reviewing, inspecting and evaluating the Contractor's property management plan(s), systems, procedures, records, and supporting documentation that pertains to Government property. This access includes all site locations and, with the Contractor’s consent, all subcontractor premises.
(2) Records of Government property shall be readily available to authorized Government personnel and shall be appropriately safeguarded.
(3) Should it be determined by the Government that the Contractor's (or subcontractor’s) property management practices are inadequate or not acceptable for the effective management and control of Government property under this contract, or present an undue risk to the Government, the Contractor shall prepare a corrective action plan when requested by the Property Administer and take all necessary corrective actions as specified by the schedule within the corrective action plan.
(4) The Contractor shall ensure Government access to subcontractor premises, and all Government property located at subcontractor premises, for the purposes of reviewing, inspecting and evaluating the subcontractor's property management plan, systems, procedures, records, and supporting documentation that pertains to Government property.
(h) Contractor Liability for Government Property. 
(1) Unless otherwise provided for in the contract, the Contractor shall not be liable for loss of Government property furnished or acquired under this contract, except when any one of the following applies—
(i) The risk is covered by insurance or the Contractor is otherwise reimbursed (to the extent of such insurance or reimbursement). The allowability of insurance costs shall be determined in accordance with 31.205-19.
(ii) Loss of Government property that is the result of willful misconduct or lack of good faith on the part of the Contractor's managerial personnel. 
(iii) The Contracting Officer has, in writing, revoked the Government's assumption of risk for loss of Government property due to a determination under paragraph (g) of this clause that the Contractor's property management practices are inadequate, and/or present an undue risk to the Government, and the Contractor failed to take timely corrective action. If the Contractor can establish by clear and convincing evidence that the loss of Government property occurred while the Contractor had adequate property management practices or the loss did not result from the Contractor's failure to maintain adequate property management practices, the Contractor shall not be held liable.
(2) The Contractor shall take all reasonable actions necessary to protect the property from further loss. The Contractor shall separate the damaged and undamaged property, place all the affected property in the best possible order, and take such other action as the Property Administrator directs.
(3) The Contractor shall do nothing to prejudice the Government's rights to recover against third parties for any loss of Government property.
(4) The Contractor shall reimburse the Government for loss of Government property, to the extent that the Contractor is financially liable for such loss, as directed by the Contracting Officer.
(5) Upon the request of the Contracting Officer, the Contractor shall, at the Government's expense, furnish to the Government all reasonable assistance and cooperation, including the prosecution of suit and the execution of instruments of assignment in favor of the Government in obtaining recovery.
(i) Equitable adjustment. Equitable adjustments under this clause shall be made in accordance with the procedures of the Changes clause. However, the Government shall not be liable for breach of contract for the following:
(1) Any delay in delivery of Government-furnished property.
(2) Delivery of Government-furnished property in a condition not suitable for its intended use.
(3) An increase, decrease, or substitution of Government-furnished property.
(4) Failure to repair or replace Government property for which the Government is responsible. Standard Form 1428.
(j) Contractor inventory disposal. Except as otherwise provided for in this contract, the Contractor shall not dispose of Contractor inventory until authorized to do so by the Plant Clearance Officer or authorizing official.
(1) Predisposal requirements. 
(i) If the Contractor determines that the property has the potential to fulfill requirements under other contracts, the Contractor, in consultation with the Property Administrator, shall request that the Contracting Officer transfer the property to the contract in question, or provide authorization for use, as appropriate. In lieu of transferring the property, the Contracting Officer may authorize the Contractor to credit the costs of Contractor-acquired property (material only) to the losing contract, and debit the gaining contract with the corresponding cost, when such material is needed for use on another contract. Property no longer needed shall be considered contractor inventory.
(ii) For any remaining Contractor-acquired property, the Contractor may purchase the property at the unit acquisition cost if desired or make reasonable efforts to return unused property to the appropriate supplier at fair market value (less, if applicable, a reasonable restocking fee that is consistent with the supplier's customary practices.)
(2) Inventory disposal schedules. 
(i) Absent separate contract terms and conditions for property disposition, and provided the property was not reutilized, transferred, or otherwise disposed of, the Contractor, as directed by the Plant Clearance Officer or authorizing official, shall use Standard Form 1428, Inventory Disposal Schedule or electronic equivalent, to identify and report—
(A) Government-furnished property that is no longer required for performance of this contract;
(B) Contractor-acquired property, to which the Government has obtained title under paragraph (e) of this clause, which is no longer required for performance of that contract; and
(C) Termination inventory.
(ii) The Contractor may annotate inventory disposal schedules to identify property the Contractor wishes to purchase from the Government, in the event that the property is offered for sale.
(iii) Separate inventory disposal schedules are required for aircraft in any condition, flight safety critical aircraft parts, and other items as directed by the Plant Clearance Officer
(iv) The Contractor shall provide the information required by FAR 52.245-1(f)(1)(iii) along with the following:
(A) Any additional; information that may facilitate understanding of the property’s intended use.
(B) For work-in-progress, the estimated percentage of completion.
(C) For precious metals in raw or bulk form, the type of metal and estimated weight.
(D) For hazardous material or property contaminated with hazardous material, the type of hazardous material.
(E) For metals in mill product form, the form, shape, treatment, hardness, temper, specification (commercial or Government) and dimensions (thickness, width and length).
(v) Property with the same description, condition code, and reporting location may be grouped in a single line item.
(vi) Scrap should be reported by “lot” along with metal content, estimated weight and estimated value.
(3) Submission requirements. 
(i) The Contractor shall submit inventory disposal schedules to the Plant Clearance Officer no later than—
(A) 30 days following the Contractor's determination that a property item is no longer required for performance of this contract;
(B) 60 days, or such longer period as may be approved by the Plant Clearance Officer, following completion of contract deliveries or performance; or
(C) 120 days, or such longer period as may be approved by the Termination Contracting Officer, following contract termination in whole or in part.
(ii) Unless the Plant Clearance Officer determines otherwise, the Contractor need not identify or report production scrap on inventory disposal schedules, and may process and dispose of production scrap in accordance with its own internal scrap procedures. The processing and disposal of other types of Government-owned scrap will be conducted in accordance with the terms and conditions of the contract or Plant Clearance Officer direction, as appropriate.
(4) Corrections. The Plant Clearance Officer may—
(i) Reject a schedule for cause (e.g., contains errors, determined to be inaccurate); and
(ii) Require the Contractor to correct an inventory disposal schedule.
(5) Postsubmission adjustments. The Contractor shall notify the Plant Clearance Officer at least 10 working days in advance of its intent to remove an item from an approved inventory disposal schedule. Upon approval of the Plant Clearance Officer, or upon expiration of the notice period, the Contractor may make the necessary adjustments to the inventory schedule.
(6) Storage.
(i) The Contractor shall store the property identified on an inventory disposal schedule pending receipt of disposal instructions. The Government's failure to furnish disposal instructions within 120 days following acceptance of an inventory disposal schedule may entitle the Contractor to an equitable adjustment for costs incurred to store such property on or after the 121st day.
(ii) The Contractor shall obtain the Plant Clearance Officer's approval to remove property from the premises where the property is currently located prior to receipt of final disposition instructions. If approval is granted, any costs incurred by the Contractor to transport or store the property shall not increase the price or fee of any Government contract. The storage area shall be appropriate for assuring the property's physical safety and suitability for use. Approval does not relieve the Contractor of any liability for such property under this contract.
(7) Disposition instructions.
(i) The Contractor shall prepare for shipment, deliver f.o.b. origin, or dispose of Contractor inventory as directed by the Plant Clearance Officer. Unless otherwise directed by the Contracting Officer or by the Plant Clearance Officer, the Contractor shall remove and destroy any markings identifying the property as U.S. Government-owned property prior to its disposal.
(ii) The Contracting Officer may require the Contractor to demilitarize the property prior to shipment or disposal. In such cases, the Contractor may be entitled to an equitable adjustment under paragraph (i) of this clause.
(8) Disposal proceeds. As directed by the Contracting Officer, the Contractor shall credit the net proceeds from the disposal of Contractor inventory to the contract, or to the Treasury of the United States as miscellaneous receipts.
(9) Subcontractor inventory disposal schedules. The Contractor shall require its Subcontractors to submit inventory disposal schedules to the Contractor in accordance with the requirements of paragraph (j)(3) of this clause.
(k) Abandonment of Government property. 
(1) The Government shall not abandon sensitive property or termination inventory without the Contractor's written consent.
(2) The Government, upon notice to the Contractor, may abandon any nonsensitive property in place, at which time all obligations of the Government regarding such property shall cease.
(3) Absent contract terms and conditions to the contrary, the Government may abandon parts removed and replaced from property as a result of normal maintenance actions, or removed from property as a result of the repair, maintenance, overhaul, or modification process. 
(4) The Government has no obligation to restore or rehabilitate the Contractor's premises under any circumstances; however, if Government-furnished property is withdrawn or is unsuitable for the intended use, or if other Government property is substituted, then the equitable adjustment under paragraph (i) of this clause may properly include restoration or rehabilitation costs.
(l) Communication. All communications under this clause shall be in writing.
(m) Contracts outside the United States. If this contract is to be performed outside of the United States and its outlying areas, the words “Government” and “Government-furnished” (wherever they appear in this clause) shall be construed as “United States Government” and “United States Government-furnished,” respectively.

I.126  52.245-9 -- Use and Charges (Apr 2012)
(a) Definitions. Definitions applicable to this contract are provided in the clause at 52.245-1, Government Property. Additional definitions as used in this clause include:
“Rental period” means the calendar period during which Government property is made available for nongovernmental purposes.
“Rental time” means the number of hours, to the nearest whole hour, rented property is actually used for nongovernmental purposes. It includes time to set up the property for such purposes, perform required maintenance, and restore the property to its condition prior to rental (less normal wear and tear).
(b) Use of Government property. The Contractor may use the Government property without charge in the performance of—
(1) Contracts with the Government that specifically authorize such use without charge;
(2) Subcontracts of any tier under Government prime contracts if the Contracting Officer having cognizance of the prime contract—
(i) Approves a subcontract specifically authorizing such use; or
(ii) Otherwise authorizes such use in writing; and
(3) Other work, if the Contracting Officer specifically authorizes in writing use without charge for such work.
(c) Rental. If granted written permission by the Contracting Officer, or if it is specifically provided for in the Schedule, the Contractor may use the Government property (except material) for a rental fee for work other than that provided in paragraph (b) of this clause. Authorizing such use of the Government property does not waive any rights of the Government to terminate the Contractor’s right to use the Government property. The rental fee shall be determined in accordance with the following paragraphs.
(d) General. 
(1) Rental requests shall be submitted to the Administrative Contracting Officer (ACO), identify the property for which rental is requested, propose a rental period, and compute an estimated rental charge by using the Contractor’s best estimate of rental time in the formulae described in paragraph (e) of this clause.
(2) The Contractor shall not use Government property for nongovernmental purposes, including Independent Research and Development, until a rental charge for real property, or estimated rental charge for other property, is agreed upon. Rented property shall be used only on a non-interference basis.
(e) Rental charge.—
(1) Real property and associated fixtures.
(i) The Contractor shall obtain, at its expense, a property appraisal from an independent licensed, accredited, or certified appraiser that computes a monthly, daily or hourly rental rate for comparable commercial property. The appraisal may be used to compute rentals under this clause throughout its effective period or, if an effective period is not stated in the appraisal, for one year following the date the appraisal was performed. The Contractor shall submit the appraisal to the ACO at least 30 days prior to the date the property is needed for nongovernmental use. Except as provided in paragraph (e)(1)(iii) of this clause, the ACO shall use the appraisal rental rate to determine a reasonable rental charge.
(ii) Rental charges shall be determined by multiplying the rental time by the appraisal rental rate expressed as a rate per hour. Monthly or daily appraisal rental rates shall be divided by 720 or 24, respectively, to determine an hourly rental rate.
(iii) When the ACO believes the appraisal rental rate is unreasonable, the ACO shall promptly notify the Contractor. The parties may agree on an alternative means for computing a reasonable rental charge.
(iv) The Contractor shall obtain, at its expense, additional property appraisals in the same manner as provided in paragraph (e)(1)(i) if the effective period has expired and the Contractor desires the continued use of property for nongovernmental use. The Contractor may obtain additional appraisals within the effective period of the current appraisal if the market prices decrease substantially.
(2) Other Government property. The Contractor may elect to compute the rental charge using the appraisal method described in paragraph (e)(1) of this clause subject to the constraints therein or the following formula in which rental time shall be expressed in increments of not less than one hour with portions of hours rounded to the next higher hour: The hourly rental charge is calculated by multiplying 2 percent of the acquisition cost by the hours of rental time, and dividing by 720.
(3) Alternative methodology. The Contractor may request consideration of an alternative basis for computing the rental charge if it considers the monthly rental rate or a time-based rental unreasonable or impractical.
(f) Rental payments. 
(1) Rent is due 60 days following completion of the rental period or as otherwise specified in the contract. The Contractor shall compute the rental due, and furnish records or other supporting data in sufficient detail to permit the ACO to verify the rental time and computation. Payment shall be made by check payable to the Treasurer of the United States and sent to the contract administration office identified in the contract, unless otherwise specified by the Contracting Officer.
(2) Interest will be charged if payment is not made by the date specified in paragraph (f)(1) of this clause. Interest will accrue at the “Renegotiation Board Interest Rate” (published in the Federal Register semiannually on or about January 1st and July 1st) for the period in which the rent is due.
(3) The Government’s acceptance of any rental payment under this clause, in whole or in part, shall not be construed as a waiver or relinquishment of any rights it may have against the Contractor stemming from the Contractor’s unauthorized use of Government property or any other failure to perform this contract according to its terms
(g) Use revocation. At any time during the rental period the Government may revoke nongovernmental use authorization and require the Contractor, at the Contractor’s expense, to return the property to the Government, restore the property to its pre-rental condition (less normal wear and tear), or both.
(h) Unauthorized use. The unauthorized use of Government property can subject a person to fines, imprisonment, or both under 18 U.S.C. 641.

I.127  52.246-25 -- Limitation of Liability – Services (Feb 1997)
(a) Except as provided in paragraphs (b) and (c) below, and except to the extent that the Contractor is expressly responsible under this contract for deficiencies in the services required to be performed under it (including any materials furnished in conjunction with those services), the Contractor shall not be liable for loss of or damage to property of the Government that --
(1) Occurs after Government acceptance of services performed under this contract; and
(2) Results from any defects or deficiencies in the services performed or materials furnished.
(b) The limitation of liability under paragraph (a) above shall not apply when a defect or deficiency in, or the Government’s acceptance of, services performed or materials furnished results from willful misconduct or lack of good faith on the part of any of the Contractor’s managerial personnel. The term “Contractor’s managerial personnel,” as used in this clause, means the Contractor’s directors, officers, and any of the Contractor’s managers, superintendents, or equivalent representatives who have supervision or direction of --
(1) All or substantially all of the Contractor’s business;
(2) All or substantially all of the Contractor’s operations at any one plant, laboratory, or separate location at which the contract is being performed; or
(3) A separate and complete major industrial operation connected with the performance of this contract.
(c) If the Contractor carries insurance, or has established a reserve for self-insurance, covering liability for loss or damage suffered by the Government through the Contractor’s performance of services or furnishing of materials under this contract, the Contractor shall be liable to the Government, to the extent of such insurance or reserve, for loss of or damage to property of the Government occurring after Government acceptance of, and resulting from any defects and deficiencies in, services performed or materials furnished under this contract.

I.128  52.247-1 -- Commercial Bill of Lading Notations (Feb 2006)
When the Contracting Officer authorizes supplies to be shipped on a commercial bill of lading and the Contractor will be reimbursed these transportation costs as direct allowable costs, the Contractor shall ensure before shipment is made that the commercial shipping documents are annotated with either of the following notations, as appropriate:
(a) If the Government is shown as the consignor or the consignee, the annotation shall be:
Transportation is for the Department of Energy and the actual total transportation charges paid to the carrier(s) by the consignor or consignee are assignable to, and shall be reimbursed by, the Government.
(b) If the Government is not shown as the consignor or the consignee, the annotation shall be:
Transportation is for the Department of Energy and the actual total transportation charges paid to the carrier(s) by the consignor or consignee shall be reimbursed by the Government, pursuant to cost-reimbursement contract No. 89303519NE000005. This may be confirmed by contacting the Contract Administration Office specified in Section G.

I.129  52.247-63 -- Preference for U.S.-Flag Air Carriers (June 2003)    
(a) Definitions. As used in this clause--
“International air transportation” means transportation by air between a place in the United States and a place outside the United States or between two places both of which are outside the United States.
“United States” means the 50 States, the District of Columbia, and outlying areas.
“U.S.-flag air carrier” means an air carrier holding a certificate under 49 U.S.C. Chapter 411.
(b) Section 5 of the International Air Transportation Fair Competitive Practices Act of 1974 (49 U.S.C. 40118) (Fly America Act) requires that all Federal agencies and Government contractors and subcontractors use U.S.-flag air carriers for U.S. Government-financed international air transportation of personnel (and their personal effects) or property, to the extent that service by those carriers is available. It requires the Comptroller General of the United States, in the absence of satisfactory proof of the necessity for foreign-flag air transportation, to disallow expenditures from funds, appropriated or otherwise established for the account of the United States, for international air transportation secured aboard a foreign-flag air carrier if a U.S.-flag air carrier is available to provide such services.
(c) If available, the Contractor, in performing work under this contract, shall use U.S.-flag carriers for international air transportation of personnel (and their personal effects) or property.
(d) In the event that the Contractor selects a carrier other than a U.S.-flag air carrier for international air transportation, the Contractor shall include a statement on vouchers involving such transportation essentially as follows:
Statement of Unavailability of U.S.-Flag Air Carriers
International air transportation of persons (and their personal effects) or property by U.S.-flag air carrier was not available or it was necessary to use foreign-flag air carrier service for the following reasons (see section 47.403 of the Federal Acquisition Regulation): [State reasons]: 
 
_____________________________________________
(End of statement)
(e) The Contractor shall include the substance of this clause, including this paragraph (e), in each subcontract or purchase under this contract that may involve international air transportation.

I.130  52.249-6 -- Termination (Cost-Reimbursement) (May 2004)
(a) The Government may terminate performance of work under this contract in whole or, from time to time, in part, if --
(1) The Contracting Officer determines that a termination is in the Government’s interest; or
(2) The Contractor defaults in performing this contract and fails to cure the default within 10 days (unless extended by the Contracting Officer) after receiving a notice specifying the default. “Default” includes failure to make progress in the work so as to endanger performance.
(b) The Contracting Officer shall terminate by delivering to the Contractor a Notice of Termination specifying whether termination is for default of the Contractor or for convenience of the Government, the extent of termination, and the effective date. If, after termination for default, it is determined that the Contractor was not in default or that the Contractor’s failure to perform or to make progress in performance is due to causes beyond the control and without the fault or negligence of the Contractor as set forth in the Excusable Delays clause, the rights and obligations of the parties will be the same as if the termination was for the convenience of the Government.
(c) After receipt of a Notice of Termination, and except as directed by the Contracting Officer, the Contractor shall immediately proceed with the following obligations, regardless of any delay in determining or adjusting any amounts due under this clause:
(1) Stop work as specified in the notice.
(2) Place no further subcontracts or orders (referred to as subcontracts in this clause), except as necessary to complete the continued portion of the contract.
(3) Terminate all subcontracts to the extent they relate to the work terminated.
(4) Assign to the Government, as directed by the Contracting Officer, all right, title, and interest of the Contractor under the subcontracts terminated, in which case the Government shall have the right to settle or to pay any termination settlement proposal arising out of those terminations.
(5) With approval or ratification to the extent required by the Contracting Officer, settle all outstanding liabilities and termination settlement proposals arising from the termination of subcontracts, the cost of which would be reimbursable in whole or in part, under this contract; approval or ratification will be final for purposes of this clause.
(6) Transfer title (if not already transferred) and, as directed by the Contracting Officer, deliver to the Government --
(i) The fabricated or unfabricated parts, work in process, completed work, supplies, and other material produced or acquired for the work terminated;
(ii) The completed or partially completed plans, drawings, information, and other property that, if the contract had been completed, would be required to be furnished to the Government; and
(iii) The jigs, dies, fixtures, and other special tools and tooling acquired or manufactured for this contract, the cost of which the Contractor has been or will be reimbursed under this contract.
(7) Complete performance of the work not terminated.
(8) Take any action that may be necessary, or that the Contracting Officer may direct, for the protection and preservation of the property related to this contract that is in the possession of the Contractor and in which the Government has or may acquire an interest.
(9) Use its best efforts to sell, as directed or authorized by the Contracting Officer, any property of the types referred to in subparagraph (c)(6) of this clause; provided, however, that the Contractor
(i) is not required to extend credit to any purchaser and
(ii) may acquire the property under the conditions prescribed by, and at prices approved by, the Contracting Officer.
The proceeds of any transfer or disposition will be applied to reduce any payments to be made by the Government under this contract, credited to the price or cost of the work, or paid in any other manner directed by the Contracting Officer.
(d) The Contractor shall submit complete termination inventory schedules no later than 120 days from the effective date of termination, unless extended in writing by the Contracting Officer upon written request of the Contractor within this 120-day period.
(e) After expiration of the plant clearance period as defined in Subpart 49.001 of the Federal Acquisition Regulation, the Contractor may submit to the Contracting Officer a list, certified as to quantity and quality, of termination inventory not previously disposed of, excluding items authorized for disposition by the Contracting Officer. The Contractor may request the Government to remove those items or enter into an agreement for their storage. Within 15 days, the Government will accept the items and remove them or enter into a storage agreement. The Contracting Officer may verify the list upon removal of the items, or if stored, within 45 days from submission of the list, and shall correct the list, as necessary, before final settlement.
(f) After termination, the Contractor shall submit a final termination settlement proposal to the Contracting Officer in the form and with the certification prescribed by the Contracting Officer. The Contractor shall submit the proposal promptly, but no later than 1 year from the effective date of termination, unless extended in writing by the Contracting Officer upon written request of the Contractor within this 1-year period. However, if the Contracting Officer determines that the facts justify it, a termination settlement proposal may be received and acted on after 1 year or any extension. If the Contractor fails to submit the proposal within the time allowed, the Contracting Officer may determine, on the basis of information available, the amount, if any, due the Contractor because of the termination and shall pay the amount determined.
(g) Subject to paragraph (f) of this clause, the Contractor and the Contracting Officer may agree on the whole or any part of the amount to be paid (including an allowance for fee) because of the termination. The contract shall be amended, and the Contractor paid the agreed amount.
(h) If the Contractor and the Contracting Officer fail to agree in whole or in part on the amount of costs and/or fee to be paid because of the termination of work, the Contracting Officer shall determine, on the basis of information available, the amount, if any, due the Contractor, and shall pay that amount, which shall include the following:
(1) All costs reimbursable under this contract, not previously paid, for the performance of this contract before the effective date of the termination, and those costs that may continue for a reasonable time with the approval of or as directed by the Contracting Officer; however, the Contractor shall discontinue those costs as rapidly as practicable.
(2) The cost of settling and paying termination settlement proposals under terminated subcontracts that are properly chargeable to the terminated portion of the contract if not included in subparagraph (h)(1) of this clause.
(3) The reasonable costs of settlement of the work terminated, including --
(i) Accounting, legal, clerical, and other expenses reasonably necessary for the preparation of termination settlement proposals and supporting data;
(ii) The termination and settlement of subcontracts (excluding the amounts of such settlements); and
(iii) Storage, transportation, and other costs incurred, reasonably necessary for the preservation, protection, or disposition of the termination inventory. If the termination is for default, no amounts for the preparation of the Contractor’s termination settlement proposal may be included.
(4) A portion of the fee payable under the contract, determined as follows:
(i) If the contract is terminated for the convenience of the Government, the settlement shall include a percentage of the fee equal to the percentage of completion of work contemplated under the contract, but excluding subcontract effort included in subcontractors’ termination proposals, less previous payments for fee.
(ii) If the contract is terminated for default, the total fee payable shall be such proportionate part of the fee as the total number of articles (or amount of services) delivered to and accepted by the Government is to the total number of articles (or amount of services) of a like kind required by the contract.
(5) If the settlement includes only fee, it will be determined under subparagraph (h)(4) of this clause.
(i) The cost principles and procedures in Part 31 of the Federal Acquisition Regulation, in effect on the date of this contract, shall govern all costs claimed, agreed to, or determined under this clause.
(j) The Contractor shall have the right of appeal, under the Disputes clause, from any determination made by the Contracting Officer under paragraph (f), (h), or (l) of this clause, except that if the Contractor failed to submit the termination settlement proposal within the time provided in paragraph (f) and failed to request a time extension, there is no right of appeal. If the Contracting Officer has made a determination of the amount due under paragraph (f), (h) or (l) of this clause, the Government shall pay the Contractor --
(1) The amount determined by the Contracting Officer if there is no right of appeal or if no timely appeal has been taken; or
(2) The amount finally determined on an appeal.
(k) In arriving at the amount due the Contractor under this clause, there shall be deducted --
(1) All unliquidated advance or other payments to the Contractor, under the terminated portion of this contract;
(2) Any claim which the Government has against the Contractor under this contract; and
(3) The agreed price for, or the proceeds of sale of materials, supplies, or other things acquired by the Contractor or sold under this clause and not recovered by or credited to the Government.
(l) The Contractor and Contracting Officer must agree to any equitable adjustment in fee for the continued portion of the contract when there is a partial termination. The Contracting Officer shall amend the contract to reflect the agreement.
(m)
(1) The Government may, under the terms and conditions it prescribes, make partial payments and payments against costs incurred by the Contractor for the terminated portion of the contract, if the Contracting Officer believes the total of these payments will not exceed the amount to which the Contractor will be entitled.
(2) If the total payments exceed the amount finally determined to be due, the Contractor shall repay the excess to the Government upon demand, together with interest computed at the rate established by the Secretary of the Treasury under 50 U.S.C. App. 1215(b)(2). Interest shall be computed for the period from the date the excess payment is received by the Contractor to the date the excess is repaid. Interest shall not be charged on any excess payment due to a reduction in the Contractor’s termination settlement proposal because of retention or other disposition of termination inventory until 10 days after the date of the retention or disposition, or a later date determined by the Contracting Officer because of the circumstances.
(n) The provisions of this clause relating to fee are inapplicable if this contract does not include a fee.

I.131  52.249-14 -- Excusable Delays (Apr 1984)
(a) Except for defaults of subcontractors at any tier, the Contractor shall not be in default because of any failure to perform this contract under its terms if the failure arises from causes beyond the control and without the fault or negligence of the Contractor. Examples of these causes are
(1) acts of God or of the public enemy,
(2) acts of the Government in either its sovereign or contractual capacity,
(3) fires,
(4) floods,
(5) epidemics,
(6) quarantine restrictions,
(7) strikes,
(8) freight embargoes, and
(9) unusually severe weather.
In each instance, the failure to perform must be beyond the control and without the fault or negligence of the Contractor. “Default” includes failure to make progress in the work so as to endanger performance.
(b) If the failure to perform is caused by the failure of a subcontractor at any tier to perform or make progress, and if the cause of the failure was beyond the control of both the Contractor and subcontractor, and without the fault or negligence of either, the Contractor shall not be deemed to be in default, unless --
(1) The subcontracted supplies or services were obtainable from other sources;
(2) The Contracting Officer ordered the Contractor in writing to purchase these supplies or services from the other source; and
(3) The Contractor failed to comply reasonably with this order.
(c) Upon request of the Contractor, the Contracting Officer shall ascertain the facts and extent of the failure. If the Contracting Officer determines that any failure to perform results from one or more of the causes above, the delivery schedule shall be revised, subject to the rights of the Government under the termination clause of this contract.

I.132  52.251-1 -- Government Supply Sources (Apr 2012)
The Contracting Officer may issue the Contractor an authorization to use Government supply sources in the performance of this contract. Title to all property acquired by the Contractor under such an authorization shall vest in the Government unless otherwise specified in the contract. The provisions of the clause at FAR 52.245-1, Government Property, apply to all property acquired under such authorization.

I.133  52.253-1 -- Computer Generated Forms (Jan 1991)
(a) Any data required to be submitted on a Standard or Optional Form prescribed by the Federal Acquisition Regulation (FAR) may be submitted on a computer generated version of the form, provided there is no change to the name, content, or sequence of the data elements on the form, and provided the form carries the Standard or Optional Form number and edition date.
(b) Unless prohibited by agency regulations, any data required to be submitted on an agency unique form prescribed by an agency supplement to the FAR may be submitted on a computer generated version of the form provided there is no change to the name, content, or sequence of the data elements on the form and provided the form carries the agency form number and edition date.
(c) If the Contractor submits a computer generated version of a form that is different than the required form, then the rights and obligations of the parties will be determined based on the content of the required form.

I.134  952.202-1 Definitions (Feb 2011)
As prescribed in 902.201, insert the clause at 48 CFR 52.202-1, Definitions, in all contracts. The following shall be added to the clause as paragraph (c):
(c) When a solicitation provision or contract clause uses a word or term that is defined in the Department of Energy Acquisition Regulation (DEAR) (48 CFR chapter 9), the word or term has the same meaning as the definition in 48 CFR 902.101 or the definition in the part, subpart, or section of 48 CFR chapter 9 where the provision or clause is prescribed in effect at the time the solicitation was issued, unless an exception in (a) applies.

I.135  952.203-70 Whistleblower Protection for Contractor Employees (DEC 2000) 
(a) The Contractor shall comply with the requirements of “DOE Contractor Employee Protection Program” at 10 CFR part 708 for work performed on behalf of DOE directly related to activities at DOE-owned or -leased sites. 
(b) The Contractor shall insert or have inserted the substance of this clause, including this paragraph (b), in subcontracts at all tiers, for subcontracts involving work performed on behalf of DOE directly related to activities at DOE-owned or leased sites.

I.136  952.204-2 Security Requirements (Aug. 2016)
(a) Responsibility. It is the Contractor's duty to protect all classified information, special nuclear material, and other DOE property. The Contractor shall, in accordance with DOE security regulations and requirements, be responsible for protecting all classified information and all classified matter (including documents, material and special nuclear material) which are in the Contractor's possession in connection with the performance of work under this contract against sabotage, espionage, loss or theft. Except as otherwise expressly provided in this contract, the Contractor shall, upon completion or termination of this contract, transmit to DOE any classified matter or special nuclear material in the possession of the Contractor or any person under the Contractor's control in connection with performance of this contract. If retention by the Contractor of any classified matter is required after the completion or termination of the contract, the Contractor shall identify the items and classification levels and categories of matter proposed for retention, the reasons for the retention, and the proposed period of retention. If the retention is approved by the Contracting Officer, the security provisions of the contract shall continue to be applicable to the classified matter retained. Special nuclear material shall not be retained after the completion or termination of the contract.
(b) Regulations. The Contractor agrees to comply with all security regulations and contract requirements of DOE as incorporated into the contract.
(c) Definition of classified information. The term Classified Information means information that is classified as Restricted Data or Formerly Restricted Data under the Atomic Energy Act of 1954, or information determined to require protection against unauthorized disclosure under Executive Order 12958, Classified National Security Information, as amended, or prior executive orders, which is identified as National Security Information.
(d) Definition of restricted data. The term Restricted Data means all data concerning design, manufacture, or utilization of atomic weapons; production of special nuclear material; or use of special nuclear material in the production of energy, but excluding data declassified or removed from the Restricted Data category pursuant to 42 U.S.C. 2162 [Section 142, as amended, of the Atomic Energy Act of 1954].
(e) Definition of formerly restricted data. The term ”Formerly Restricted Data” means information removed from the Restricted Data category based on a joint determination by DOE or its predecessor agencies and the Department of Defense that the information—(1) Relates primarily to the military utilization of atomic weapons; and (2) can be adequately protected as National Security Information. However, such information is subject to the same restrictions on transmission to other countries or regional defense organizations that apply to Restricted Data.
(f) Definition of national security information. The term “National Security Information” means information that has been determined, pursuant to Executive Order 12958, Classified National Security Information, as amended, or any predecessor order, to require protection against unauthorized disclosure, and that is marked to indicate its classified status when in documentary form.
(g) Definition of special nuclear material. The term “special nuclear material” means—(1) Plutonium, uranium enriched in the isotope 233 or in the isotope 235, and any other material which, pursuant to 42 U.S.C. 2071 [section 51 as amended, of the Atomic Energy Act of 1954] has been determined to be special nuclear material, but does not include source material; or (2) any material artificially enriched by any of the foregoing, but does not include source material.
(h) Access authorizations of personnel. (1) The Contractor shall not permit any individual to have access to any classified information or special nuclear material, except in accordance with the Atomic Energy Act of 1954, and the DOE's regulations and contract requirements applicable to the particular level and category of classified information or particular category of special nuclear material to which access is required.
(2) The Contractor must conduct a thorough review, as defined at 48 CFR 904.401, of an uncleared applicant or uncleared employee, and must test the individual for illegal drugs, prior to selecting the individual for a position requiring a DOE access authorization.
(i) A review must—Verify an uncleared applicant's or uncleared employee's educational background, including any high school diploma obtained within the past five years, and degrees or diplomas granted by an institution of higher learning; contact listed employers for the last three years and listed personal references; conduct local law enforcement checks when such checks are not prohibited by state or local law or regulation and when the uncleared applicant or uncleared employee resides in the jurisdiction where the Contractor is located; and conduct a credit check and other checks as appropriate.
(ii) Contractor reviews are not required for an applicant for DOE access authorization who possesses a current access authorization from DOE or another Federal agency, or whose access authorization may be reapproved without a federal background investigation pursuant to Executive Order 12968, Access to Classified Information (August 4, 1995), Sections 3.3(c) and (d).
(iii) In collecting and using this information to make a determination as to whether it is appropriate to select an uncleared applicant or uncleared employee to a position requiring an access authorization, the Contractor must comply with all applicable laws, regulations, and Executive Orders, including those—(A) Governing the processing and privacy of an individual's information, such as the Fair Credit Reporting Act, Americans with Disabilities Act (ADA), and Health Insurance Portability and Accountability Act; and (B) prohibiting discrimination in employment, such as under the ADA, Title VII and the Age Discrimination in Employment Act, including with respect to pre- and post-offer of employment disability related questioning.
(iv) In addition to a review, each candidate for a DOE access authorization must be tested to demonstrate the absence of any illegal drug, as defined in 10 CFR 707.4. All positions requiring access authorizations are deemed testing designated positions in accordance with 10 CFR part 707. All employees possessing access authorizations are subject to applicant, random or for cause testing for use of illegal drugs. DOE will not process candidates for a DOE access authorization unless their tests confirm the absence from their system of any illegal drug.
(v) When an uncleared applicant or uncleared employee receives an offer of employment for a position that requires a DOE access authorization, the Contractor shall not place that individual in such a position prior to the individual's receipt of a DOE access authorization, unless an approval has been obtained from the head of the cognizant local security office. If the individual is hired and placed in the position prior to receiving an access authorization, the uncleared employee may not be afforded access to classified information or matter or special nuclear material (in categories requiring access authorization) until an access authorization has been granted.
(vi) The Contractor must maintain a record of information concerning each uncleared applicant or uncleared employee who is selected for a position requiring an access authorization. Upon request only, the following information will be furnished to the head of the cognizant local DOE Security Office:
(A) The date(s) each Review was conducted;
(B) Each entity that provided information concerning the individual;
(C) A certification that the review was conducted in accordance with all applicable laws, regulations, and Executive Orders, including those governing the processing and privacy of an individual's information collected during the review;
(D) A certification that all information collected during the review was reviewed and evaluated in accordance with the Contractor's personnel policies; and
(E) The results of the test for illegal drugs.
(i) Criminal liability. It is understood that disclosure of any classified information relating to the work or services ordered hereunder to any person not entitled to receive it, or failure to protect any classified information, special nuclear material, or other Government property that may come to the Contractor or any person under the Contractor's control in connection with work under this contract, may subject the Contractor, its agents, employees, or Subcontractors to criminal liability under the laws of the United States (see the Atomic Energy Act of 1954, 42 U.S.C. 2011 et seq.; 18 U.S.C. 793 and 794).
(j) Foreign ownership, control, or influence. (1) The Contractor shall immediately provide the cognizant security office written notice of any change in the extent and nature of foreign ownership, control or influence over the Contractor which would affect any answer to the questions presented in the Standard Form (SF) 328, Certificate Pertaining to Foreign Interests, executed prior to award of this contract. The Contractor will submit the Foreign Ownership, Control or Influence (FOCI) information in the format directed by DOE. When completed the Contractor must print and sign one copy of the SF 328 and submit it to the Contracting Officer. In addition, any notice of changes in ownership or control which are required to be reported to the Securities and Exchange Commission, the Federal Trade Commission, or the Department of Justice, shall also be furnished concurrently to the Contracting Officer.
(2) If a Contractor has changes involving foreign ownership, control, or influence, DOE must determine whether the changes will pose an undue risk to the common defense and security. In making this determination, DOE will consider proposals made by the Contractor to avoid or mitigate foreign influences.
(3) If the cognizant security office at any time determines that the Contractor is, or is potentially, subject to foreign ownership, control, or influence, the Contractor shall comply with such instructions as the Contracting Officer shall provide in writing to protect any classified information or special nuclear material.
(4) The Contracting Officer may terminate this contract for default either if the Contractor fails to meet obligations imposed by this clause or if the Contractor creates a foreign ownership, control, or influence situation in order to avoid performance or a termination for default. The Contracting Officer may terminate this contract for convenience if the Contractor becomes subject to foreign ownership, control, or influence and for reasons other than avoidance of performance of the contract, cannot, or chooses not to, avoid or mitigate the foreign ownership, control, or influence problem.
(k) Employment announcements. When placing announcements seeking applicants for positions requiring access authorizations, the Contractor shall include in the written vacancy announcement, a notification to prospective applicants that reviews, and tests for the absence of any illegal drug as defined in 10 CFR 707.4, will be conducted by the employer and a background investigation by the Federal government may be required to obtain an access authorization prior to employment, and that subsequent reinvestigations may be required. If the position is covered by the Counterintelligence Evaluation Program regulations at 10 CFR part 709, the announcement should also alert applicants that successful completion of a counterintelligence evaluation may include a counterintelligence-scope polygraph examination.
(l) Flow down to subcontracts. The Contractor agrees to insert terms that conform substantially to the language of this clause, including this paragraph, in all subcontracts under its contract that will require subcontractor employees to possess access authorizations. Additionally, the Contractor must require such subcontractors to have an existing DOD or DOE facility clearance or submit a completed SF 328, Certificate Pertaining to Foreign Interests, as required in 48 CFR 952.204-73, Facility Clearance, and obtain a foreign ownership, control and influence determination and facility clearance prior to award of a subcontract. Information to be provided by a subcontractor pursuant to this clause may be submitted directly to the Contracting Officer. For purposes of this clause, subcontractor means any subcontractor at any tier and the term “Contracting Officer” means the DOE Contracting Officer. When this clause is included in a subcontract, the term “Contractor” shall mean subcontractor and the term “contract” shall mean subcontract.

I.137  952.204-70 Classification/Declassification (SEP 1997)
In the performance of work under this contract, the Contractor or subcontractor shall comply with all provisions of the Department of Energy's regulations and mandatory DOE directives which apply to work involving the classification and declassification of information, documents, or material. In this section, “information” means facts, data, or knowledge itself; “document” means the physical medium on or in which information is recorded; and “material” means a product or substance which contains or reveals information, regardless of its physical form or characteristics. Classified information is “Restricted Data” and “Formerly Restricted Data” (classified under the Atomic Energy Act of 1954, as amended) and “National Security Information” (classified under Executive Order 12958 or prior Executive Orders).
The original decision to classify or declassify information is considered an inherently Governmental function. For this reason, only Government personnel may serve as original classifiers, i.e., Federal Government Original Classifiers. Other personnel (Government or Contractor) may serve as derivative classifiers which involves making classification decisions based upon classification guidance which reflect decisions made by Federal Government Original Classifiers.
The Contractor or subcontractor shall ensure that any document or material that may contain classified information is reviewed by either a Federal Government or a Contractor Derivative Classifier in accordance with classification regulations including mandatory DOE directives and classification/declassification guidance furnished to the Contractor by the Department of Energy to determine whether it contains classified information prior to dissemination. For information which is not addressed in classification/declassification guidance, but whose sensitivity appears to warrant classification, the Contractor or subcontractor shall ensure that such information is reviewed by a Federal Government Original Classifier.
In addition, the Contractor or subcontractor shall ensure that existing classified documents (containing either Restricted Data or Formerly Restricted Data or National Security Information) which are in its possession or under its control are periodically reviewed by a Federal Government or Contractor Derivative Declassifier in accordance with classification regulations, mandatory DOE directives and classification/declassification guidance furnished to the Contractor by the Department of Energy to determine if the documents are no longer appropriately classified. Priorities for declassification review of classified documents shall be based on the degree of public and researcher interest and the likelihood of declassification upon review. Documents which no longer contain classified information are to be declassified. Declassified documents then shall be reviewed to determine if they are publicly releasable. Documents which are declassified and determined to be publicly releasable are to be made available to the public in order to maximize the public's access to as much Government information as possible while minimizing security costs.
The Contractor or subcontractor shall insert this clause in any subcontract which involves or may involve access to classified information.

I.138  952.204-75  Public Affairs (DEC 2000) 
(a) The Contractor must cooperate with the Department in releasing unclassified information to the public and news media regarding DOE policies, programs, and activities relating to its effort under the contract. The responsibilities under this clause must be accomplished through coordination with the Contracting Officer and appropriate DOE public affairs personnel in accordance with procedures defined by the Contracting Officer. 
(b) The Contractor is responsible for the development, planning, and coordination of proactive approaches for the timely dissemination of unclassified information regarding DOE activities onsite and offsite, including, but not limited to, operations and programs. Proactive public affairs programs may utilize a variety of communication media, including public workshops, meetings or hearings, open houses, newsletters, press releases, conferences, audio/visual presentations, speeches, forums, tours, and other appropriate stakeholder interactions. 
(c) The Contractor's internal procedures must ensure that all releases of information to the public and news media are coordinated through, and approved by, a management official at an appropriate level within the Contractor's organization. 
(d) The Contractor must comply with DOE procedures for obtaining advance clearances on oral, written, and audio/visual informational material prepared for public dissemination or use. 
(e) Unless prohibited by law, and in accordance with procedures defined by the Contracting Officer, the Contractor must notify the Contracting Officer and appropriate DOE public affairs personnel of communications or contacts with Members of Congress relating to the effort performed under the contract. 
(f) In accordance with procedures defined by the Contracting Officer, the Contractor must notify the Contracting Officer and appropriate DOE public affairs personnel of activities or situations that may attract regional or national news media attention and of non-routine inquiries from national news media relating to the effort performed under the contract. 
(g) In releases of information to the public and news media, the Contractor must fully and accurately identify the Contractor's relationship to the Department and fully and accurately credit the Department for its role in funding programs and projects resulting in scientific, technical, and other achievements.

I.139  952.204-77 Computer Security (AUG 2006) 
(a) Definitions. (1) Computer means desktop computers, portable computers, computer networks (including the DOE Network and local area networks at or controlled by DOE organizations), network devices, automated information systems, and or other related computer equipment owned by, leased, or operated on behalf of the DOE.
(2) Individual means a DOE Contractor or subcontractor employee, or any other person who has been granted access to a DOE computer or to information on a DOE computer, and does not include a member of the public who sends an e-mail message to a DOE computer or who obtains information available to the public on DOE Web sites.
(b) Access to DOE computers. A Contractor shall not allow an individual to have access to information on a DOE computer unless—
(1) The individual has acknowledged in writing that the individual has no expectation of privacy in the use of a DOE computer; and
(2) The individual has consented in writing to permit access by an authorized investigative agency to any DOE computer used during the period of that individual's access to information on a DOE computer, and for a period of three years thereafter.
(c) No expectation of privacy. Notwithstanding any other provision of law (including any provision of law enacted by the Electronic Communications Privacy Act of 1986), no individual using a DOE computer shall have any expectation of privacy in the use of that computer.
(d) Written records. The Contractor is responsible for maintaining written records for itself and subcontractors demonstrating compliance with the provisions of paragraph (b) of this section. The Contractor agrees to provide access to these records to the DOE, or its authorized agents, upon request.
(e) Subcontracts. The Contractor shall insert this clause, including this paragraph (e), in subcontracts under this contract that may provide access to computers owned, leased or operated on behalf of the DOE.

I.140  952.208-70 Printing (APR 1984)
The Contractor shall not engage in, nor subcontract for, any printing (as that term is defined in Title I of the U.S. Government Printing and Binding Regulations in effect on the effective date of this contract) in connection with the performance of work under this contract. Provided, however, that performance of a requirement under this contract involving the duplication of less than 5,000 copies of a single unit, or no more than 25,000 units in the aggregate of multiple units, will not be deemed to be printing. A unit is defined as one sheet, size 81⁄2 by 11 inches one side only, one color. A requirement is defined as a single publication document.
(1) The term printing includes the following processes: composition, plate making, presswork, binding, microform publishing, or the end items produced by such processes.
(2) If fulfillment of the contract will necessitate reproduction in excess of the limits set forth above, the Contractor shall notify the Contracting Officer in writing and obtain the Contracting Officer's approval prior to acquiring on DOE's behalf production, acquisition, and dissemination of printed matter. Such printing must be obtained from the Government Printing Office (GPO), a contract source designated by GPO or a Joint Committee on Printing authorized federal printing plant.
(3) Printing services not obtained in compliance with this guidance will result in the cost of such printing being disallowed.
(4) The Contractor will include in each of his subcontracts hereunder a provision substantially the same as this clause including this paragraph (4).

I.141  952.215-70 Key Personnel (DEC 2000) 
(a) The personnel listed below or elsewhere in this contract [Insert cross-reference, if applicable] are considered essential to the work being performed under this contract. Before removing, replacing, or diverting any of the listed or specified personnel, the Contractor must: (1) Notify the Contracting Officer reasonably in advance; (2) submit justification (including proposed substitutions) in sufficient detail to permit evaluation of the impact on this contract; and (3) obtain the Contracting Officer's written approval. Notwithstanding the foregoing, if the Contractor deems immediate removal or suspension of any member of its management team is necessary to fulfill its obligation to maintain satisfactory standards of employee competency, conduct, and integrity under the clause at 48 CFR 970.5203-3, Contractor's Organization, the Contractor may remove or suspend such person at once, although the Contractor must notify Contracting Officer prior to or concurrently with such action. 
(b) The list of personnel may, with the consent of the contracting parties, be amended from time to time during the course of the contract to add or delete personnel.
[See Section H]

I.142  952.223-75 Preservation of Individual Occupational Radiation Exposure Records (APR 1984)
Individual occupational radiation exposure records generated in the performance of work under this contract shall be generated and maintained by the contractor in accordance with 36 CFR Chapter XII, Subchapter B, “Records Management,” the National Archives and Records Administration (NARA)-approved DOE Records Disposition Schedules, and shall be operated as a DOE Privacy Act system of records, in accordance with the Privacy Act.

I.143  952.223-78 Sustainable Acquisition Program (OCT 2010)
(a) Pursuant to Executive Order 13423, Strengthening Federal Environmental, Energy and Transportation Management, and Executive Order 13514, Federal Leadership in Environmental, Energy, and Economic Performance, the Department of Energy (DOE) is committed to managing its facilities in an environmentally preferable and sustainable manner that will promote the natural environment and protect the health and well being of its Federal employees and contractor service providers. In the performance of work under this contract, the Contractor shall provide its services in a manner that promotes the natural environment, reduces greenhouse gas emissions and protects the health and well being of Federal employees, contract service providers and visitors using the facility.
(b) Green purchasing or sustainable acquisition has several interacting initiatives. The Contractor must comply with initiatives that are current as of the contract award date. DOE may require compliance with revised initiatives from time to time. The Contractor may request an equitable adjustment to the terms of its contract using the procedures in the Changes clause of the contract. The initiatives important to these Orders are explained on the following Government or Industry Internet Sites:
(1) Recycled Content Products are described at http://epa.gov/cpg.
(2) Biobased Products are described at http://www.biopreferred.gov/.
(3) Energy efficient products are at http://energystar.gov/products for Energy Star products.
(4) Energy efficient products are at http://www.femp.energy.gov/procurement for FEMP designated products.
(5) Environmentally preferable and energy efficient electronics including desktop computers, laptops and monitors are at http://www.epeat.net the Electronic Products Environmental Assessment Tool (EPEAT) the Green Electronics Council site.
(6) Green house gas emission inventories are required, including Scope 3 emissions which include contractor emissions. These are discussed at Section 13 of Executive Order 13514 which can be found at http://www.archives.gov/federal-register/executive-orders/disposition.html.
(7) Non-Ozone Depleting Alternative Products are at http://www.epa.gov/ozone/strathome.html.
(8) Water efficient plumbing products are at http://epa.gov/watersense.
(c) The clauses at FAR 52.223-2, Affirmative Procurement of Biobased Products under Service and Construction Contracts, 52.223-15, Energy Efficiency in Energy Consuming Products, and 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts, require the use of products that have biobased content, are energy efficient, or have recycled content. To the extent that the services provided by the Contractor require provision of any of the above types of products, the Contractor must provide the energy efficient and environmentally sustainable type of product unless that type of product—
(1) Is not available;
(2) Is not life cycle cost effective or does not exceed 110% of the price of alternative items if life cycle cost data is unavailable (EPEAT is an example of lifecycle costs that have been analyzed by DOE and found to be acceptable at the silver and gold level);
(3) Does not meet performance needs; or,
(4) Cannot be delivered in time to meet a critical need.
(d) In the performance of this contract, the Contractor shall comply with the requirements of Executive Order 13423, Strengthening Federal Environmental, Energy and Transportation Management, (http://www.epa.gov/greeningepa/practices/eo13423.htm) and Executive Order 13514, Federal Leadership in Environmental, Energy, and Economic Performance (http://www.archives.gov/federal-register/executive-orders/disposition.html). The Contractor shall also consider the best practices within the DOE Acquisition Guide, Chapter 23, Acquisition Considerations Regarding Federal Leadership in Environmental, Energy, and Economic Performance. This guide includes information concerning recycled content products, biobased products, energy efficient products, water efficient products, alternative fuels and vehicles, non-ozone depleting substances and other environmentally preferable products and services. This guide is available on the Internet at: http://management.energy.gov/documents/AcqGuide23pt0Rev1.pdf.
(e) Contractors must establish and maintain a documented energy management program which includes requirements for energy and water efficient equipment, EnergyStar or WaterSense, as applicable and procedures for verification of purchases, following the criteria in DOE Order 430.2B, Departmental Energy, Renewable Energy, and Transportation Management, Attachment 1, or its successor to the extent required elsewhere in the contract. This requirement should not be flowed down to subcontractors.
(f) In complying with the requirements of paragraph (c) of this clause, the Contractor(s) shall coordinate its activities with and submit required reports through the Environmental Sustainability Coordinator or equivalent position. Reporting under this paragraph and paragraphs (g) and (h) of this clause is only required if the contract or subcontract offers subcontracting opportunities for energy efficient and environmentally sustainable products or services exceeding $100,000 in any contract year.
(g) The Contractor shall prepare and submit performance reports, if required, using prescribed DOE formats, at the end of the Federal fiscal year, on matters related to the acquisition of environmentally preferable and sustainable products and services. This is a material delivery under the contract. Failure to perform this requirement may be considered a failure that endangers performance of this contract and may result in termination for default.
(h) These provisions shall be flowed down only to first tier subcontracts exceeding the simplified acquisition threshold that support operation of the DOE facility and offer significant subcontracting opportunities for energy efficient or environmentally sustainable products or services. The Subcontractor, if subcontracting opportunities for sustainable and environmentally preferable products or services exceed the threshold in paragraph (f) of this clause, will comply with the procedures in paragraphs (c) through (f) of this clause regarding the collection of all data necessary to generate the reports required under paragraphs (c) through (f) of this clause, and submit the reports directly to the Prime Contractor's Environmental Sustainability Coordinator at the supported facility. The Subcontractor will advise the Contractor if it is unable to procure energy efficient and environmentally sustainable items and cite which of the reasons in paragraph (c) of this clause apply. The reports may be submitted at the conclusion of the subcontract term provided that the subcontract delivery term is not multi-year in nature. If the delivery term is multi-year, the Subcontractor shall report its accomplishments for each Federal fiscal year in a manner and at a time or times acceptable to both parties. Failure to comply with these reporting requirements may be considered a breach of contract with attendant consequences.
(i) When this clause is used in a subcontract, the word “Contractor” will be understood to mean “Subcontractor.”

I.144  952.226-71 Utilization of Energy Policy Act Target Entities (JUN 1996)
(a) Definition. Energy Policy Act target groups, as used in this provision means—
(1) An institution of higher education that meets the requirements of 34 CFR 600.4(a) and has a student enrollment that consists of at least 20 percent—
(i) Hispanic Americans, i.e., students whose origins are in Mexico, Puerto Rico, Cuba, or Central or South America, or any combination thereof, or
(ii) Native Americans, i.e., American Indians, Eskimos, Aleuts, and Native Hawaiians, or any combination thereof;
(2) Institutions of higher learning determined to be Historically Black Colleges and Universities by the Secretary of Education pursuant to 34 CFR 608.2; and
(3) Small business concerns, as defined under section 3 of the Small Business Act (15 U.S.C. 632), that are owned and controlled by individuals who are both socially and economically disadvantaged within the meaning of section 8(d) of the Small Business Act (15 U.S.C. 637(d)) or by a woman or women.
(b) Obligation. In addition to its obligations under the clause of this contract entitled Utilization of Small Business, Small Disadvantaged and Women-Owned Small Business Concerns, the contractor, in performance of this contract, agrees to provide its best efforts to competitively award subcontracts to entities from among the Energy Policy Act target groups.

I.145  952.226-72 Energy Policy Act Subcontracting Goals and Reporting Requirements (JUN 1996)
(a) Definition. Energy Policy Act target groups, as used in this provision means—
(1) An institution of higher education that meets the requirements of 34 CFR 600.4(a), and has a student enrollment that consists of at least 20 percent—
(i) Hispanic Americans, i.e., students whose origins are in Mexico, Puerto Rico, Cuba, or Central or South America, or any combination thereof, or
(ii) Native Americans, i.e., American Indians, Eskimos, Aleuts, and Native Hawaiians, or any combination thereof;
(2) Institutions of higher learning determined to be Historically Black Colleges and Universities by the Secretary of Education pursuant to 34 CFR 608.2; and
(3) Small business concerns, as defined under section 3 of the Small Business Act (15 U.S.C. 632), that are owned and controlled by individuals who are both socially and economically disadvantaged within the meaning of section 8(d) of the Small Business Act (15 U.S.C. 637(d)) or by a woman or women.
(b) Goals. The Contractor, in performance of this contract, agrees to provide its best efforts to award subcontracts to the following classes of entities—
(1) Small business concerns controlled by socially and economically disadvantaged individuals or by women: * * * percent;
(2) Historically Black colleges and universities: * * * percent; and 
(3) Colleges or universities having a student body in which more than 20 percent of the students are Hispanic Americans or Native Americans: * * * percent.
[* * * These goals are stated in a percentage reflecting the relationship of estimated award value of subcontracts to the value of this contract and appear elsewhere in this contract.]
(c) Reporting requirements. (1) The Contractor agrees to report, on an annual Federal Government fiscal year basis, its progress against the goals by providing the actual annual dollar value of subcontract payments for the preceding 12-month period, and the relationship of those payments to the incurred contract costs for the same period. Reports submitted pursuant to this clause must be received by the Contracting Officer (or designee) not later than 45 days after the end of the reporting period.
(2) If the contract includes reporting requirements under FAR 52.219-9, Small Business Subcontracting Plan, the Contractor's progress against the goals stated in paragraph (b) of this clause shall be included as an addendum to Standard Form (SF) 294, Subcontracting Report for Individual Contracts, and/or SF 295, Summary Subcontract Report, as applicable, for the period that corresponds to the end of the Federal Government fiscal year.

I.146  952.226-74 Displaced Employee Hiring Preference (JUN 1997)
(a) Definition. Eligible employee means a current or former employee of a contractor or subcontractor employed at a Department of Energy Defense Nuclear Facility (1) whose position of employment has been, or will be, involuntarily terminated (except if terminated for cause), (2) who has also met the eligibility criteria contained in the Department of Energy guidance for contractor work force restructuring, as may be amended or supplemented from time to time, and (3) who is qualified for a particular job vacancy with the Department or one of its contractors with respect to work under its contract with the Department at the time the particular position is available.
(b) Consistent with Department of Energy guidance for contractor work force restructuring, as may be amended or supplemented from time to time, the Contractor agrees that it will provide a preference in hiring to an eligible employee to the extent practicable for work performed under this contract.
(c) The requirements of this clause shall be included in subcontracts at any tier (except for subcontracts for commercial items pursuant to 41 U.S.C. 403) expected to exceed $500,000.

I.147  952.227-13 Patent Rights—Acquisition by the Government (SEP 1997)
(a) Definitions.
Invention, as used in this clause, means any invention or discovery which is or may be patentable or otherwise protectable under title 35 of the United States Code or any novel variety of plant that is or may be protectable under the Plant Variety Protection Act (7 U.S.C. 2321, et seq.).
Practical application, as used in this clause, means to manufacture, in the case of a composition or product; to practice, in the case of a process or method; or to operate, in the case of a machine or system; and, in each case, under such conditions as to establish that the invention is being utilized and that its benefits are, to the extent permitted by law or Government regulations, available to the public on reasonable terms.
Subject invention, as used in this clause, means any invention of the Contractor conceived or first actually reduced to practice in the course of or under this contract.
Patent Counsel, as used in this clause, means the Department of Energy Patent Counsel assisting the procuring activity.
DOE patent waiver regulations, as used in this clause, means the Department of Energy patent waiver regulations in effect on the date of award of this contract. See 10 CFR part 784.
Agency licensing regulations and applicable agency licensing regulations, as used in this clause, mean the Department of Energy patent licensing regulations at 10 CFR part 781.
(b) Allocations of principal rights—(1) Assignment to the Government. The Contractor agrees to assign to the Government the entire right, title, and interest throughout the world in and to each subject invention, except to the extent that rights are retained by the Contractor under subparagraph (b)(2) and paragraph (d) of this clause.
(2) Greater rights determinations. (i) The Contractor, or an employee-inventor after consultation with the Contractor, may request greater rights than the nonexclusive license and the foreign patent rights provided in paragraph (d) of this clause on identified inventions in accordance with the DOE patent waiver regulations. A request for a determination of whether the Contractor or the employee-inventor is entitled to acquire such greater rights must be submitted to the Patent Counsel with a copy to the Contracting Officer at the time of the first disclosure of the invention pursuant to subparagraph (e)(2) of this clause, or not later than 8 months thereafter, unless a longer period is authorized in writing by the Contracting Officer for good cause shown in writing by the Contractor. Each determination of greater rights under this contract shall be subject to paragraph (c) of this clause, unless otherwise provided in the greater rights determination, and to the reservations and conditions deemed to be appropriate by the Secretary of Energy or designee.
(ii) Within two (2) months after the filing of a patent application, the Contractor shall provide the filing date, serial number and title, a copy of the patent application (including an English-language version if filed in a language other than English), and, promptly upon issuance of a patent, provide the patent number and issue date for any subject invention in any country for which the Contractor has been granted title or the right to file and prosecute on behalf of the United States by the Department of Energy.
(iii) Not less than thirty (30) days before the expiration of the response period for any action required by the Patent and Trademark Office, notify the Patent Counsel of any decision not to continue prosecution of the application.
(iv) Upon request, the Contractor shall furnish the Government an irrevocable power to inspect and make copies of the patent application file.
(c) Minimum rights acquired by the Government. (1) With respect to each subject invention to which the Department of Energy grants the Contractor principal or exclusive rights, the Contractor agrees as follows:
(i) The Contractor hereby grants to the Government a nonexclusive, nontransferable, irrevocable, paid-up license to practice or have practiced each subject invention throughout the world by or on behalf of the Government of the United States (including any Government agency).
(ii) The Contractor agrees that with respect to any subject invention in which DOE has granted it title, DOE has the right in accordance with the procedures in the DOE patent waiver regulations (10 CFR part 784) to require the Contractor, an assignee, or exclusive licensee of a subject invention to grant a nonexclusive, partially exclusive, or exclusive license in any field of use to a responsible applicant or applicants, upon terms that are reasonable under the circumstances, and if the Contractor, assignee, or exclusive licensee refuses such a request, DOE has the right to grant such a license itself if it determines that—
(A) Such action is necessary because the Contractor or assignee has not taken, or is not expected to take within a reasonable time, effective steps to achieve practical application of the subject invention in such field of use;
(B) Such action is necessary to alleviate health or safety needs which are not reasonably satisfied by the Contractor, assignee, or their licensees;
(C) Such action is necessary to meet requirements for public use specified by Federal regulations and such requirements are not reasonably satisfied by the Contractor, assignee, or licensees; or
(D) Such action is necessary because the agreement required by paragraph (i) of this clause has neither been obtained nor waived or because a licensee of the exclusive right to use or sell any subject invention in the United States is in breach of such agreement.
(iii) The Contractor agrees to submit on request periodic reports no more frequently than annually on the utilization of a subject invention or on efforts at obtaining such utilization of a subject invention or on efforts at obtaining such utilization that are being made by the Contractor or its licensees or assignees. Such reports shall include information regarding the status of development, date of first commercial sale or use, gross royalties received by the Contractor, and such other data and information as DOE may reasonably specify. The Contractor also agrees to provide additional reports as may be requested by DOE in connection with any march-in proceedings undertaken by that agency in accordance with subparagraph (c)(1)(ii) of this clause. To the extent data or information supplied under this section is considered by the Contractor, its licensee, or assignee to be privileged and confidential and is so marked, the Department of Energy agrees that, to the extent permitted by law, it will not disclose such information to persons outside the Government.
(iv) The Contractor agrees, when licensing a subject invention, to arrange to avoid royalty charges on acquisitions involving Government funds, including funds derived through a Military Assistance Program of the Government or otherwise derived through the Government, to refund any amounts received as royalty charges on a subject invention in acquisitions for, or on behalf of, the Government, and to provide for such refund in any instrument transferring rights in the invention to any party.
(v) The Contractor agrees to provide for the Government's paid-up license pursuant to subparagraph (c)(1)(i) of this clause in any instrument transferring rights in a subject invention and to provide for the granting of licenses as required by subparagraph (c)(1)(ii) of this clause, and for the reporting of utilization information as required by subparagraph (c)(1)(iii) of this clause, whenever the instrument transfers principal or exclusive rights in a subject invention.
(2) Nothing contained in this paragraph (c) shall be deemed to grant to the Government any rights with respect to any invention other than a subject invention.
(d) Minimum rights to the Contractor. (1) The Contractor is hereby granted a revocable, nonexclusive, royalty-free license in each patent application filed in any country on a subject invention and any resulting patent in which the Government obtains title, unless the Contractor fails to disclose the subject invention within the times specified in subparagraph (e)(2) of this clause. The Contractor's license extends to its domestic subsidiaries and affiliates, if any, within the corporate structure of which the Contractor is a part and includes the right to grant sublicenses of the same scope to the extent the Contractor was legally obligated to do so at the time the contract was awarded. The license is transferable only with the approval of DOE except when transferred to the successor of that part of the Contractor's business to which the invention pertains.
(2) The Contractor's domestic license may be revoked or modified by DOE to the extent necessary to achieve expeditious practical application of the subject invention pursuant to an application for an exclusive license submitted in accordance with applicable provisions in 37 CFR part 404 and agency licensing regulations. This license will not be revoked in that field of use or the geographical areas in which the Contractor has achieved practical applications and continues to make the benefits of the invention reasonably accessible to the public. The license in any foreign country may be revoked or modified at the discretion of DOE to the extent the Contractor, its licensees, or its domestic subsidiaries or affiliates have failed to achieve practical application in that foreign country.
(3) Before revocation or modification of the license, DOE will furnish the Contractor a written notice of its intention to revoke or modify the license, and the Contractor will be allowed 30 days (or such other time as may be authorized by DOE for good cause shown by the Contractor) after the notice to show cause why the license should not be revoked or modified. The Contractor has the right to appeal, in accordance with applicable agency licensing regulations and 37 CFR part 404 concerning the licensing of Government-owned inventions, any decision concerning the revocation or modification of its license.
(4) The Contractor may request the right to acquire patent rights to a subject invention in any foreign country where the Government has elected not to secure such rights, subject to the conditions in subparagraphs (d)(4)(i) through (d)(4)(vii) of this clause. Such request must be made in writing to the Patent Counsel as part of the disclosure required by subparagraph (e)(2) of this clause, with a copy to the DOE Contracting Officer. DOE approval, if given, will be based on a determination that this would best serve the national interest.
(i) The recipient of such rights, when specifically requested by DOE, and three years after issuance of a foreign patent disclosing the subject invention, shall furnish DOE a report stating:
(A) The commercial use that is being made, or is intended to be made, of said invention, and
(B) The steps taken to bring the invention to the point of practical application or to make the invention available for licensing.
(ii) The Government shall retain at least an irrevocable, nonexclusive, paid-up license to make, use, and sell the invention throughout the world by or on behalf of the Government (including any Government agency) and States and domestic municipal governments, unless the Secretary of Energy or designee determines that it would not be in the public interest to acquire the license for the States and domestic municipal governments.
(iii) If noted elsewhere in this contract as a condition of the grant of an advance waiver of the Government's title to inventions under this contract, or, if no advance waiver was granted but a waiver of the Government's title to an identified invention is granted pursuant to subparagraph (b)(2) of this clause upon a determination by the Secretary of Energy that it is in the Government's best interest, this license shall include the right of the Government to sublicense foreign governments pursuant to any existing or future treaty or agreement with such foreign governments.
(iv) Subject to the rights granted in subparagraphs (d)(1), (2), and (3) of this clause, the Secretary of Energy or designee shall have the right to terminate the foreign patent rights granted in this subparagraph (d)(4) in whole or in part unless the recipient of such rights demonstrates to the satisfaction of the Secretary of Energy or designee that effective steps necessary to accomplish substantial utilization of the invention have been taken or within a reasonable time will be taken.
(v) Subject to the rights granted in subparagraphs (d)(1), (2), and (3) of this clause, the Secretary of Energy or designee shall have the right, commencing four years after foreign patent rights are accorded under this subparagraph (d)(4), to require the granting of a nonexclusive or partially exclusive license to a responsible applicant or applicants, upon terms reasonable under the circumstances, and in appropriate circumstances to terminate said foreign patent rights in whole or in part, following a hearing upon notice thereof to the public, upon a petition by an interested person justifying such hearing:
(A) If the Secretary of Energy or designee determines, upon review of such material as he deems relevant, and after the recipient of such rights or other interested person has had the opportunity to provide such relevant and material information as the Secretary or designee may require, that such foreign patent rights have tended substantially to lessen competition or to result in undue market concentration in any section of the United States in any line of commerce to which the technology relates; or
(B) Unless the recipient of such rights demonstrates to the satisfaction of the Secretary of Energy or designee at such hearing that the recipient has taken effective steps, or within a reasonable time thereafter is expected to take such steps, necessary to accomplish substantial utilization of the invention.
(vi) If the contractor is to file a foreign patent application on a subject invention, the Government agrees, upon written request, to use its best efforts to withhold publication of such invention disclosures for such period of time as specified by Patent Counsel, but in no event shall the Government or its employees be liable for any publication thereof.
(vii) Subject to the license specified in subparagraphs (d) (1), (2), and (3) of this clause, the contractor or inventor agrees to convey to the Government, upon request, the entire right, title, and interest in any foreign country in which the contractor or inventor fails to have a patent application filed in a timely manner or decides not to continue prosecution or to pay any maintenance fees covering the invention. To avoid forfeiture of the patent application or patent, the contractor or inventor shall, not less than 60 days before the expiration period for any action required by any patent office, notify the Patent Counsel of such failure or decision, and deliver to the Patent Counsel, the executed instruments necessary for the conveyance specified in this paragraph.
(e) Invention identification, disclosures, and reports. (1) The Contractor shall establish and maintain active and effective procedures to assure that subject inventions are promptly identified and disclosed to Contractor personnel responsible for patent matters within 6 months of conception and/or first actual reduction to practice, whichever occurs first in the performance of work under this contract. These procedures shall include the maintenance of laboratory notebooks or equivalent records and other records as are reasonably necessary to document the conception and/or the first actual reduction to practice of subject inventions, and records that show that the procedures for identifying and disclosing the inventions are followed. Upon request, the Contractor shall furnish the Contracting Officer a description of such procedures for evaluation and for determination as to their effectiveness.
(2) The Contractor shall disclose each subject invention to the DOE Patent Counsel with a copy to the Contracting Officer within 2 months after the inventor discloses it in writing to Contractor personnel responsible for patent matters or, if earlier, within 6 months after the Contractor becomes aware that a subject invention has been made, but in any event before any on sale, public use, or publication of such invention known to the Contractor. The disclosure to DOE shall be in the form of a written report and shall identify the contract under which the invention was made and the inventor(s). It shall be sufficiently complete in technical detail to convey a clear understanding, to the extent known at the time of the disclosure, of the nature, purpose, operation, and physical, chemical, biological, or electrical characteristics of the invention. The disclosure shall also identify any publication, on sale, or public use of the invention and whether a manuscript describing the invention has been submitted for publication and, if so, whether it has been accepted for publication at the time of disclosure. In addition, after disclosure to DOE, the Contractor shall promptly notify Patent Counsel of the acceptance of any manuscript describing the invention for publication or of any on sale or public use planned by the Contractor. The report should also include any request for a greater rights determination in accordance with subparagraph (b)(2) of this clause. When an invention is disclosed to DOE under this paragraph, it shall be deemed to have been made in the manner specified in Sections (a)(1) and (a)(2) of 42 U.S.C. 5908, unless the Contractor contends in writing at the time the invention is disclosed that is was not so made.
(3) The Contractor shall furnish the Contracting Officer the following:
(i) Interim reports every 12 months (or such longer period as may be specified by the Contracting Officer) from the date of the contract, listing all subject inventions during that period, and including a statment that all subject inventions have been disclosed (or that there are not such inventions), and that such disclosure has been made in accordance with the procedures required by paragraph (e)(1) of this clause.
(ii) A final report, within 3 months after completion of the contracted work listing all subject inventions or containing a statement that there were no such inventions, and listing all subcontracts at any tier containing a patent right clause or containing a statement that there were no such subcontracts.
(4) The Contractor agrees to require, by written agreement, its employees, other than clerical and nontechnical employees, to disclose promptly in writing to personnel identified as responsible for the administration of patent matters and in a format suggested by the Contractor each subject invention made under contract in order that the Contractor can comply with the disclosure provisions of paragraph (c) of this clause, and to execute all papers necessary to file patent applications on subject inventions and to establish the Government's rights in the subject inventions. This disclosure format should require, as a minimum, the information required by subparagraph (e)(2) of this clause.
(5) The Contractor agrees, subject to FAR 27.302(j), that the Government may duplicate and disclose subject invention disclosures and all other reports and papers furnished or required to be furnished pursuant to this clause.
(f) Examination of records relating to inventions. (1) The Contracting Officer or any authorized representative shall, until 3 years after final payment under this contract, have the right to examine any books (including laboratory notebooks), records, and documents of the Contractor relating to the conception or first actual reduction to practice of inventions in the same field of technology as the work under this contract to determine whether—
(i) Any such inventions are subject inventions;
(ii) The Contractor has established and maintains the procedures required by subparagraphs (e) (1) and (4) of this clause;
(iii) The Contractor and its inventors have complied with the procedures.
(2) If the Contracting Officer learns of an unreported Contractor invention which the Contracting Officer believes may be a subject invention, the Contractor may be required to disclose the invention to DOE for a determination of ownership rights.
(3) Any examination of records under this paragraph will be subject to appropriate conditions to protect the confidentiality of the information involved.
(g) Withholding of payment (This paragraph does not apply to subcontracts).
(1) Any time before final payment under this contract, the Contracting Officer may, in the Government's interest, withhold payment until a reserve not exceeding $50,000 or 5 percent of the amount of this contract, whichever is less, shall have been set aside if, in the Contracting Officer's opinion, the Contractor fails to—
(i) Convey to the Government, using a DOE-approved form, the title and/or rights of the Government in each subject invention as required by this clause.
(ii) Establish, maintain, and follow effective procedures for identifying and disclosing subject inventions pursuant to subparagraph (e)(1) of this clause;
(iii) Disclose any subject invention pursuant to subparagraph (e)(2) of this clause;
(iv) Deliver acceptable interim reports pursuant to subparagraph (e)(3)(i) of this clause; or
(v) Provide the information regarding subcontracts pursuant to subparagraph (h)(4) of this clause.
(2) Such reserve or balance shall be withheld until the Contracting Officer has determined that the Contractor has rectified whatever deficiencies exist and has delivered all reports, disclosures, and other information required by this clause.
(3) Final payment under this contract shall not be made before the Contractor delivers to the Contracting Officer all disclosures of subject inventions required by subparagraph (e)(2) of this clause, and acceptable final report pursuant to subparagraph (e)(3)(ii) of this clause, and the Patent Counsel has issued a patent clearance certification to the Contracting Officer.
(4) The Contracting Officer may decrease or increase the sums withheld up to the maximum authorized above. No amount shall be withheld under this paragraph while the amount specified by this paragraph is being withheld under other provisions of the contract. The withholding of any amount or the subsequent payment thereof shall not be construed as a waiver of any Government rights.
(h) Subcontracts. (1) The contractor shall include the clause at 48 CFR 952.227-11 (suitably modified to identify the parties) in all subcontracts, regardless of tier, for experimental, developmental, demonstration, or research work to be performed by a small business firm or domestic nonprofit organization, except where the work of the subcontract is subject to an Exceptional Circumstances Determination by DOE. In all other subcontracts, regardless of tier, for experimental, developmental, demonstration, or research work, the contractor shall include this clause (suitably modified to identify the parties). The contractor shall not, as part of the consideration for awarding the subcontract, obtain rights in the subcontractor's subject inventions.
(2) In the event of a refusal by a prospective subcontractor to accept such a clause the Contractor—
(i) Shall promptly submit a written notice to the Contracting Officer setting forth the subcontractor's reasons for such refusal and other pertinent information that may expedite disposition of the matter; and
(ii) Shall not proceed with such subcontract without the written authorization of the Contracting Officer.
(3) In the case of subcontracts at any tier, DOE, the subcontractor, and Contractor agree that the mutual obligations of the parties created by this clause constitute a contract between the subcontractor and DOE with respect to those matters covered by this clause.
(4) The Contractor shall promptly notify the Contracting Officer in writing upon the award of any subcontract at any tier containing a patent rights clause by identifying the subcontractor, the applicable patent rights clause, the work to be performed under the subcontract, and the dates of award and estimated completion. Upon request of the Contracting Officer, the Contractor shall furnish a copy of such subcontract, and, no more frequently than annually, a listing of the subcontracts that have been awarded.
(5) The contractor shall identify all subject inventions of the subcontractor of which it acquires knowledge in the performance of this contract and shall notify the Patent Counsel, with a copy to the contracting officer, promptly upon identification of the inventions.
(i) Preference United States industry. Unless provided otherwise, no Contractor that receives title to any subject invention and no assignee of any such Contractor shall grant to any person the exclusive right to use or sell any subject invention in the United States unless such person agrees that any products embodying the subject invention will be manufactured substantially in the United States. However, in individual cases, the requirement may be waived by the Government upon a showing by the Contractor or assignee that reasonable but unsuccessful efforts have been made to grant licenses on similar terms to potential licensees that would be likely to manufacture substantially in the United States or that under the circumstances domestic manufacture is not commercially feasible.
(j) Atomic energy. (1) No claim for pecuniary award of compensation under the provisions of the Atomic Energy Act of 1954, as amended, shall be asserted with respect to any invention or discovery made or conceived in the course of or under this contract.
(2) Except as otherwise authorized in writing by the Contracting Officer, the Contractor will obtain patent agreements to effectuate the provisions of subparagraph (e)(1) of this clause from all persons who perform any part of the work under this contract, except nontechnical personnel, such as clerical employees and manual laborers.
(k) Background patents. (1) Background patent means a domestic patent covering an invention or discovery which is not a subject invention and which is owned or controlled by the Contractor at any time through the completion of this contract:
(i) Which the contractor, but not the Government, has the right to license to others without obligation to pay royalties thereon, and
(ii) Infringement of which cannot reasonably be avoided upon the practice of any specific process, method, machine, manufacture, or composition of matter (including relatively minor modifications thereof) which is a subject of the research, development, or demonstration work performed under this contract.
(2) The Contractor agrees to and does hereby grant to the Government a royalty-free, nonexclusive license under any background patent for purposes of practicing a subject of this contract by or for the Government in research, development, and demonstration work only.
(3) The Contractor also agrees that upon written application by DOE, it will grant to responsible parties, for purposes of practicing a subject of this contract, nonexclusive licenses under any background patent on terms that are reasonable under the circumstances. If, however, the Contractor believes that exclusive rights are necessary to achieve expeditious commercial development or utilization, then a request may be made to DOE for DOE approval of such licensing by the Contractor.
(4) Notwithstanding subparagraph (k)(3) of this clause, the contractor shall not be obligated to license any background patent if the Contractor demonstrates to the satisfaction of the Secretary of Energy or designee that:
(i) A competitive alternative to the subject matter covered by said background patent is commercially available or readily introducible from one or more other sources; or
(ii) The Contractor or its licensees are supplying the subject matter covered by said background patent in sufficient quantity and at reasonable prices to satisfy market needs, or have taken effective steps or within a reasonable time are expected to take effective steps to so supply the subject matter.
(l) Publication. It is recognized that during the course of the work under this contract, the Contractor or its employees may from time to time desire to release or publish information regarding scientific or technical developments conceived or first actually reduced to practice in the course of or under this contract. In order that public disclosure of such information will not adversely affect the patent interests of DOE or the Contractor, patent approval for release of publication shall be secured from Patent Counsel prior to any such release or publication.
(m) Forfeiture of rights in unreported subject inventions. (1) The Contractor shall forfeit and assign to the Government, at the request of the Secretary of Energy or designee, all rights in any subject invention which the Contractor fails to report to Patent Counsel within six months after the time the Contractor:
(i) Files or causes to be filed a United States or foreign patent application thereon; or
(ii) Submits the final report required by subparagraph (e)(2)(ii) of this clause, whichever is later.
(2) However, the Contractor shall not forfeit rights in a subject invention if, within the time specified in subparagraph (m)(1) of this clause, the Contractor:
(i) Prepares a written decision based upon a review of the record that the invention was neither conceived nor first actually reduced to practice in the course of or under the contract and delivers the decision to Patent Counsel, with a copy to the Contracting Officer; or
(ii) Contending that the invention is not a subject invention, the Contractor nevertheless discloses the invention and all facts pertinent to this contention to the Patent Counsel, with a copy to the Contracting Officer; or
(iii) Establishes that the failure to disclose did not result from the Contractor's fault or negligence.
(3) Pending written assignment of the patent application and patents on a subject invention determined by the Secretary of Energy or designee to be forfeited (such determination to be a final decision under the Disputes clause of this contract), the Contractor shall be deemed to hold the invention and the patent applications and patents pertaining thereto in trust for the Government. The forfeiture provision of this paragraph (m) shall be in addition to and shall not supersede other rights and remedies which the Government may have with respect to subject inventions.

I.148  952.231-71 Insurance—Litigation and Claims (JUL 2013)
(a) The contractor must comply with 10 CFR part 719, contractor Legal Management Requirements, if applicable.
(b)(1) Except as provided in paragraph (b)(2) of this clause, the contractor shall procure and maintain such bonds and insurance as required by law or approved in writing by the Contracting Officer.
(2) The contractor may, with the approval of the Contracting Officer, maintain a self-insurance program in accordance with FAR 28.308; provided that, with respect to workers' compensation, the contractor is qualified pursuant to statutory authority.
(3) All bonds and insurance required by this clause shall be in a form and amount and for those periods as the Contracting Officer may require or approve and with sureties and insurers approved by the Contracting Officer.
(c) The contractor agrees to submit for the Contracting Officer's approval, to the extent and in the manner required by the Contracting Officer, any other bonds and insurance that are maintained by the contractor in connection with the performance of this contract and for which the contractor seeks reimbursement. If an insurance cost (whether a premium for commercial insurance or related to self-insurance) includes a portion covering costs made unallowable elsewhere in the contract, and the share of the cost for coverage for the unallowable cost is determinable, the portion of the cost that is otherwise an allowable cost under this contract is reimbursable to the extent determined by the Contracting Officer.
(d) Except as provided in paragraph (f) of this clause, or specifically disallowed elsewhere in this contract, the contractor shall be reimbursed—
(1) For that portion of the reasonable cost of bonds and insurance allocable to this contract required in accordance with contract terms or approved under this clause, and
(2) For liabilities (and reasonable expenses incidental to such liabilities, including litigation costs) to third persons not compensated by insurance without regard to the limitation of cost or limitation of funds clause of this contract.
(e) The Government's liability under paragraph (d) of this clause is subject to the availability of appropriated funds. Nothing in this contract shall be construed as implying that the Congress will, at a later date, appropriate funds sufficient to meet deficiencies.
(f)(1) Notwithstanding any other provision of this contract, the contractor shall not be reimbursed for liabilities to third parties, including contractor employees, and directly associated costs which may include but are not limited to litigation costs, counsel fees, judgment and settlements—
(i) Which are otherwise unallowable by law or the provisions of this contract, including the cost reimbursement limitations contained in 48 CFR part 970.31, as supplemented by 48 CFR part 931;
(ii) For which the contractor has failed to insure or to maintain insurance as required by law, this contract, or by the written direction of the Contracting Officer; or
(iii) Which were caused by contractor managerial personnel's—
(A) Willful misconduct;
(B) Lack of good faith; or
(C) Failure to exercise prudent business judgment, which means failure to act in the same manner as a prudent person in the conduct of competitive business; or, in the case of a non-profit educational institution, failure to act in the manner that a prudent person would under the circumstances prevailing at the time the decision to incur the cost is made.
(2) The term “contractor's managerial personnel” is defined in the Property clause in this contract.
(g)(1) All litigation costs, including counsel fees, judgments and settlements shall be segregated and accounted for by the contractor separately. If the Contracting Officer provisionally disallows such costs, then the contractor may not use funds advanced by DOE under the contract to finance the litigation.
(2) Punitive damages are not allowable unless the act or failure to act which gave rise to the liability resulted from compliance with specific terms and conditions of the contract or written instructions from the Contracting Officer.
(3) The portion of the cost of insurance obtained by the contractor that is allocable to coverage of liabilities referred to in paragraph (f) of this clause is not allowable.
(h) The contractor may at its own expense and not as an allowable cost procure for its own protection insurance to compensate the contractor for any unallowable or non-reimbursable costs incurred in connection with contract performance.

I.149  952.242-70 Technical Direction (DEC 2000) 
(a) Performance of the work under this contract shall be subject to the technical direction of the DOE Contracting Officer's Representative (COR). The term “technical direction” is defined to include, without limitation: 
(1) Providing direction to the Contractor that redirects contract effort, shift work emphasis between work areas or tasks, require pursuit of certain lines of inquiry, fill in details, or otherwise serve to accomplish the contractual Statement of Work. 
(2) Providing written information to the Contractor that assists in interpreting drawings, specifications, or technical portions of the work description. 
(3) Reviewing and, where required by the contract, approving, technical reports, drawings, specifications, and technical information to be delivered by the Contractor to the Government. 
(b) The Contractor will receive a copy of the written COR designation from the Contracting Officer. It will specify the extent of the COR's authority to act on behalf of the Contracting Officer. 
(c) Technical direction must be within the scope of work stated in the contract. The COR does not have the authority to, and may not, issue any technical direction that— 
(1) Constitutes an assignment of additional work outside the Statement of Work; 
(2) Constitutes a change as defined in the contract clause entitled “Changes;” 
(3) In any manner causes an increase or decrease in the total estimated contract cost, the fee (if any), or the time required for contract performance; 
(4) Changes any of the expressed terms, conditions or specifications of the contract; or 
(5) Interferes with the Contractor's right to perform the terms and conditions of the contract. 
(d) All technical direction shall be issued in writing by the COR. 
(e) The Contractor must proceed promptly with the performance of technical direction duly issued by the COR in the manner prescribed by this clause and within its authority under the provisions of this clause. If, in the opinion of the Contractor, any instruction or direction by the COR falls within one of the categories defined in (c)(1) through (c)(5) of this clause, the Contractor must not proceed and must notify the Contracting Officer in writing within five (5) working days after receipt of any such instruction or direction and must request the Contracting Officer to modify the contract accordingly. Upon receiving the notification from the Contractor, the Contracting Officer must— 
(1) Advise the Contractor in writing within thirty (30) days after receipt of the Contractor's letter that the technical direction is within the scope of the contract effort and does not constitute a change under the Changes clause of the contract; 
(2) Advise the Contractor in writing within a reasonable time that the Government will issue a written change order; or 
(3) Advise the Contractor in writing within a reasonable time not to proceed with the instruction or direction of the COR. 
(f) A failure of the Contractor and Contracting Officer either to agree that the technical direction is within the scope of the contract or to agree upon the contract action to be taken with respect to the technical direction will be subject to the provisions of the clause entitled “Disputes.”

I. 150  952.250-70 Nuclear Hazards Indemnity Agreement (AUG 2016)
(a) Authority. This clause is incorporated into this contract pursuant to the authority contained in subsection 170d. of the Atomic Energy Act of 1954, as amended (hereinafter called the Act.)
(b) Definitions. The definitions set out in the Act shall apply to this clause.
(c) Financial protection. Except as hereafter permitted or required in writing by DOE, the Contractor will not be required to provide or maintain, and will not provide or maintain at Government expense, any form of financial protection to cover public liability, as described in paragraph (d)(2) below. DOE may, however, at any time require in writing that the Contractor provide and maintain financial protection of such a type and in such amount as DOE shall determine to be appropriate to cover such public liability, provided that the costs of such financial protection are reimbursed to the Contractor by DOE.
(d)(1) Indemnification. To the extent that the Contractor and other persons indemnified are not compensated by any financial protection permitted or required by DOE, DOE will indemnify the Contractor and other persons indemnified against (i) claims for public liability as described in subparagraph (d)(2) of this clause; and (ii) such legal costs of the Contractor and other persons indemnified as are approved by DOE, provided that DOE's liability, including such legal costs, shall not exceed the amount set forth in section 170e.(1)(B) of the Act in the aggregate for each nuclear incident or precautionary evacuation occurring within the United States or $500 million in the aggregate for each nuclear incident occurring outside the United States, irrespective of the number of persons indemnified in connection with this contract.
(2) The public liability referred to in subparagraph (d)(1) of this clause is public liability as defined in the Act which (i) arises out of or in connection with the activities under this contract, including transportation; and (ii) arises out of or results from a nuclear incident or precautionary evacuation, as those terms are defined in the Act.
(e)(1) Waiver of defenses. In the event of a nuclear incident, as defined in the Act, arising out of nuclear waste activities, as defined in the Act, the Contractor, on behalf of itself and other persons indemnified, agrees to waive any issue or defense as to charitable or governmental immunity.
(2) In the event of an extraordinary nuclear occurrence which—
(i) Arises out of, results from, or occurs in the course of the construction, possession, or operation of a production or utilization facility; or
(ii) Arises out of, results from, or occurs in the course of transportation of source material, by-product material, or special nuclear material to or from a production or utilization facility; or
(iii) Arises out of or results from the possession, operation, or use by the Contractor or a subcontractor of a device utilizing special nuclear material or by-product material, during the course of the contract activity; or
(iv) Arises out of, results from, or occurs in the course of nuclear waste activities, the Contractor, on behalf of itself and other persons indemnified, agrees to waive—
(A) Any issue or defense as to the conduct of the claimant (including the conduct of persons through whom the claimant derives its cause of action) or fault of persons indemnified, including, but not limited to—
(1) Negligence;
(2) Contributory negligence;
(3) Assumption of risk; or
(4) Unforeseeable intervening causes, whether involving the conduct of a third person or an act of God;
(B) Any issue or defense as to charitable or governmental immunity; and
(C) Any issue or defense based on any statute of limitations, if suit is instituted within 3 years from the date on which the claimant first knew, or reasonably could have known, of his injury or change and the cause thereof. The waiver of any such issue or defense shall be effective regardless of whether such issue or defense may otherwise be deemed jurisdictional or relating to an element in the cause of action. The waiver shall be judicially enforceable in accordance with its terms by the claimant against the person indemnified.
(v) The term extraordinary nuclear occurrence means an event which DOE has determined to be an extraordinary nuclear occurrence as defined in the Act. A determination of whether or not there has been an extraordinary nuclear occurrence will be made in accordance with the procedures in 10 CFR part 840.
(vi) For the purposes of that determination, offsite as that term is used in 10 CFR part 840 means away from “the contract location” which phrase means any DOE facility, installation, or site at which contractual activity under this contract is being carried on, and any contractor-owned or controlled facility, installation, or site at which the Contractor is engaged in the performance of contractual activity under this contract.
(3) The waivers set forth above—
(i) Shall be effective regardless of whether such issue or defense may otherwise be deemed jurisdictional or relating to an element in the cause of action;
(ii) Shall be judicially enforceable in accordance with its terms by the claimant against the person indemnified;
(iii) Shall not preclude a defense based upon a failure to take reasonable steps to mitigate damages;
(iv) Shall not apply to injury or damage to a claimant or to a claimant's property which is intentionally sustained by the claimant or which results from a nuclear incident intentionally and wrongfully caused by the claimant;
(v) Shall not apply to injury to a claimant who is employed at the site of and in connection with the activity where the extraordinary nuclear occurrence takes place, if benefits therefor are either payable or required to be provided under any workmen's compensation or occupational disease law;
(vi) Shall not apply to any claim resulting from a nuclear incident occurring outside the United States;
(vii) Shall be effective only with respect to those obligations set forth in this clause and in insurance policies, contracts or other proof of financial protection; and
(viii) Shall not apply to, or prejudice the prosecution or defense of, any claim or portion of claim which is not within the protection afforded under (A) the limit of liability provisions under subsection 170e. of the Act, and (B) the terms of this agreement and the terms of insurance policies, contracts, or other proof of financial protection.
(f) Notification and litigation of claims. The Contractor shall give immediate written notice to DOE of any known action or claim filed or made against the Contractor or other person indemnified for public liability as defined in paragraph (d)(2). Except as otherwise directed by DOE, the Contractor shall furnish promptly to DOE, copies of all pertinent papers received by the Contractor or filed with respect to such actions or claims. DOE shall have the right to, and may collaborate with, the Contractor and any other person indemnified in the settlement or defense of any action or claim and shall have the right to (1) require the prior approval of DOE for the payment of any claim that DOE may be required to indemnify hereunder; and (2) appear through the Attorney General on behalf of the Contractor or other person indemnified in any action brought upon any claim that DOE may be required to indemnify hereunder, take charge of such action, and settle or defend any such action. If the settlement or defense of any such action or claim is undertaken by DOE, the Contractor or other person indemnified shall furnish all reasonable assistance in effecting a settlement or asserting a defense.
(g) Continuity of DOE obligations. The obligations of DOE under this clause shall not be affected by any failure on the part of the Contractor to fulfill its obligation under this contract and shall be unaffected by the death, disability, or termination of existence of the Contractor, or by the completion, termination or expiration of this contract.
(h) Effect of other clauses. The provisions of this clause shall not be limited in any way by, and shall be interpreted without reference to, any other clause of this contract, including the clause entitled Contract Disputes, provided, however, that this clause shall be subject to the clauses entitled Covenant Against Contingent Fees, and Accounts, records, and inspection, and any provisions that are later added to this contract as required by applicable Federal law, including statutes, executive orders and regulations, to be included in Nuclear Hazards Indemnity Agreements.
(i) Civil penalties. The Contractor and its subcontractors and suppliers who are indemnified under the provisions of this clause are subject to civil penalties, pursuant to 234A of the Act, for violations of applicable DOE nuclear-safety related rules, regulations, or orders.
(j) Criminal penalties. Any individual director, officer, or employee of the Contractor or of its subcontractors and suppliers who are indemnified under the provisions of this clause are subject to criminal penalties, pursuant to 223(c) of the Act, for knowing and willful violation of the Atomic Energy Act of 1954, as amended, and applicable DOE nuclear safety-related rules, regulations or orders which violation results in, or, if undetected, would have resulted in a nuclear incident.
(k) Inclusion in subcontracts. The Contractor shall insert this clause in any subcontract which may involve the risk of public liability, as that term is defined in the Act and further described in paragraph (d)(2) above. However, this clause shall not be included in subcontracts in which the subcontractor is subject to Nuclear Regulatory Commission (NRC) financial protection requirements under section 170b. of the Act or NRC agreements of indemnification under section 170c. or k. of the Act for the activities under the subcontract.

I.151  952.247-70 Foreign Travel (JUN 2010) 
Contractor foreign travel shall be conducted pursuant to the requirements contained in Department of Energy (DOE) Order 551.1C, Official Foreign Travel, or its successor in effect at the time of award.

I.152  952.251-70 Contractor Employee Travel Discounts (AUG 2009) 
(a) The Contractor shall take advantage of travel discounts offered to Federal Contractor employee travelers by AMTRAK, hotels, motels, or car rental companies, when use of such discounts would result in lower overall trip costs and the discounted services are reasonably available. Vendors providing these services may require the Contractor employee to furnish them a letter of identification signed by the authorized Contracting Officer. 
(b) Contracted airlines. Contractors are not eligible for GSA contract city pair fares. 
(c) Discount rail service. AMTRAK voluntarily offers discounts to Federal travelers on official business and sometimes extends those discounts to Federal contractor employees. 
(d) Hotels/motels. Many lodging providers extend their discount rates for Federal employees to Federal contractor employees. 
(e) Car rentals. The Surface Deployment and Distribution Command (SDDC) of the Department of Defense negotiates rate agreements with car rental companies that are available to Federal travelers on official business. Some car rental companies extend those discounts to Federal contractor employees. 
(f) Obtaining travel discounts. (1) To determine which vendors offer discounts to Government contractors, the Contractor may review commercial publications such as the Official Airline guides Official Traveler, Innovata, or National Telecommunications. The Contractor may also obtain this information from GSA contract Travel Management Centers or the Department of Defense's Commercial Travel Offices. 
(2) The vendor providing the service may require the Government contractor to furnish a letter signed by the Contracting Officer. The following illustrates a standard letter of identification. 
OFFICIAL AGENCY LETTERHEAD 
TO: Participating Vendor 
SUBJECT: OFFICIAL TRAVEL OF GOVERNMENT CONTRACTOR
(FULL NAME OF TRAVELER), the bearer of this letter is an employee of (COMPANY NAME) which has a contract with this agency under Government contract (CONTRACT NUMBER). During the period of the contract (GIVE DATES), AND WITH THE APPROVAL OF THE CONTRACT VENDOR, the employee is eligible and authorized to use available travel discount rates in accordance with Government contracts and/or agreements. Government Contract City Pair fares are not available to Contractors. 
SIGNATURE, Title and telephone number of Contracting Officer

I.153  970.5204-1 Counterintelligence (DEC 2010) 
(a) The Contractor shall take all reasonable precautions in the work under this contract to protect DOE programs, facilities, technology, personnel, unclassified sensitive information and classified matter from foreign intelligence threats and activities conducted for governmental or industrial purposes, in accordance with DOE Order 475.1, Counterintelligence Program, or its successor; Executive Order 12333, U.S. Intelligence Activities; and other pertinent national and Departmental Counterintelligence requirements. 
(b) The Contractor shall appoint a qualified employee(s) to function as the Contractor Counterintelligence Officer. The Contractor Counterintelligence Officer will be responsible for conducting defensive Counterintelligence briefings and debriefings of employees traveling to foreign countries or interacting with foreign nationals; providing thoroughly documented written reports relative to targeting, suspicious activity and other matters of Counterintelligence interest; immediately reporting targeting, suspicious activity and other Counterintelligence concerns to the DOE Headquarters Counterintelligence Division; and providing assistance to other elements of the U.S. Intelligence Community as stated in the aforementioned Executive Order, the DOE Counterintelligence Order, and other pertinent national and Departmental Counterintelligence requirements.

I.154  970.5227-1 Rights in Data—Facilities (DEC 2000)
(a) Definitions. (1) Computer data bases, as used in this clause, means a collection of data in a form capable of, and for the purpose of, being stored in, processed, and operated on by a computer. The term does not include computer software.
(2) Computer software, as used in this clause, means (i) computer programs which are data comprising a series of instructions, rules, routines, or statements, regardless of the media in which recorded, that allow or cause a computer to perform a specific operation or series of operations and (ii) data comprising source code listings, design details, algorithms, processes, flow charts, formulae, and related material that would enable the computer program to be produced, created, or compiled. The term does not include computer data bases.
(3) Data, as used in this clause, means recorded information, regardless of form or the media on which it may be recorded. The term includes technical data and computer software. The term “data” does not include data incidental to the administration of this contract, such as financial, administrative, cost and pricing, or management information.
(4) Limited rights data, as used in this clause, means data, other than computer software, developed at private expense that embody trade secrets or are commercial or financial and confidential or privileged. The Government's rights to use, duplicate, or disclose limited rights data are as set forth in the Limited Rights Notice of subparagraph (e) of this clause.
(5) Restricted computer software, as used in this clause, means computer software developed at private expense and that is a trade secret; is commercial or financial and is confidential or privileged; or is published copyrighted computer software, including minor modifications of any such computer software. The Government's rights to use, duplicate, or disclose restricted computer software are as set forth in the Restricted Rights Notice of paragraph (f) of this clause.
(6) Technical data, as used in this clause, means recorded data, regardless of form or characteristic, that are of a scientific or technical nature. Technical data does not include computer software, but does include manuals and instructional materials and technical data formatted as a computer data base.
(7) Unlimited rights, as used in this clause, means the right of the Government to use, disclose, reproduce, prepare derivative works, distribute copies to the public, including by electronic means, and perform publicly and display publicly, in any manner, including by electronic means, and for any purpose whatsoever, and to have or permit others to do so.
(b) Allocation of Rights. (1) The Government shall have:
(i) Ownership of all technical data and computer software first produced in the performance of this Contract;
(ii) Unlimited rights in technical data and computer software specifically used in the performance of this Contract, except as provided herein regarding copyright, limited rights data, or restricted computer software, or except for other data specifically protected by statute for a period of time or, where, approved by DOE, appropriate instances of the DOE Strategic Partnership Projects Program; 
(iii) The right to inspect technical data and computer software first produced or specifically used in the performance of this Contract at all reasonable times. The Contractor shall make available all necessary facilities to allow DOE personnel to perform such inspection; 
(iv) The right to have all technical data and computer software first produced or specifically used in the performance of this Contract delivered to the Government or otherwise disposed of by the Contractor, either as the contracting officer may from time to time direct during the progress of the work or in any event as the contracting officer shall direct upon completion or termination of this Contract. The Contractor agrees to leave a copy of such data at the facility or plant to which such data relate, and to make available for access or to deliver to the Government such data upon request by the contracting officer. If such data are limited rights data or restricted computer software, the rights of the Government in such data shall be governed solely by the provisions of paragraph (e) of this clause (“Rights in Limited Rights Data”) or paragraph (f) of this clause (“Rights in Restricted Computer Software”); and 
(v) The right to remove, cancel, correct, or ignore any markings not authorized by the terms of this Contract on any data furnished hereunder if, in response to a written inquiry by DOE concerning the propriety of the markings, the Contractor fails to respond thereto within 60 days or fails to substantiate the propriety of the markings. In either case DOE will notify the Contractor of the action taken. 
(2) The Contractor shall have: 
(i) The right to withhold limited rights data and restricted computer software unless otherwise provided in accordance with the provisions of this clause; and 
(ii) The right to use for its private purposes, subject to patent, security or other provisions of this Contract, data it first produces in the performance of this Contract, except for data in DOE's Uranium Enrichment Technology, including diffusion, centrifuge, and atomic vapor laser isotope separation, provided the data requirements of this Contract have been met as of the date of the private use of such data. 
(3) The Contractor agrees that for limited rights data or restricted computer software or other technical, business or financial data in the form of recorded information which it receives from, or is given access to by, DOE or a third party, including a DOE Contractor or subcontractor, and for technical data or computer software it first produces under this Contract which is authorized to be marked by DOE, the Contractor shall treat such data in accordance with any restrictive legend contained thereon. 
(c) Copyrighted Material. (1) The Contractor shall not, without prior written authorization of the Patent Counsel, assert copyright in any technical data or computer software first produced in the performance of this contract. To the extent such authorization is granted, the Government reserves for itself and others acting on its behalf, a nonexclusive, paid-up, irrevocable, world-wide license for Governmental purposes to publish, distribute, translate, duplicate, exhibit, and perform any such data copyrighted by the Contractor. 
(2) The Contractor agrees not to include in the technical data or computer software delivered under the contract any material copyrighted by the Contractor and not to knowingly include any material copyrighted by others without first granting or obtaining at no cost a license therein for the benefit of the Government of the same scope as set forth in paragraph (c)(1) of this clause. If the Contractor believes that such copyrighted material for which the license cannot be obtained must be included in the technical data or computer software to be delivered, rather than merely incorporated therein by reference, the Contractor shall obtain the written authorization of the contracting officer to include such material in the technical data or computer software prior to its delivery. 
(d) Subcontracting. (1) Unless otherwise directed by the contracting officer, the Contractor agrees to use in subcontracts in which technical data or computer software is expected to be produced or in subcontracts for supplies that contain a requirement for production or delivery of data in accordance with the policy and procedures of 48 CFR Subpart 27.4 as supplemented by 48 CFR 927.401 through 927.409, the clause entitled, “Rights in Data-General” at 48 CFR 52.227-14 modified in accordance with 927.409(a) and including Alternate V. Alternates II through IV of that clause may be included as appropriate with the prior approval of DOE Patent Counsel, and the Contractor shall not acquire rights in a subcontractor's limited rights data or restricted computer software, except through the use of Alternates II or III, respectively, without the prior approval of DOE Patent Counsel. The clause at 48 CFR 52.227-16, Additional Data Requirements, shall be included in subcontracts in accordance with DEAR 927.409(h). The contractor shall use instead the Rights in Data-Facilities clause at 48 CFR 970.5227-1 in subcontracts, including subcontracts for related support services, involving the design or operation of any plants or facilities or specially designed equipment for such plants or facilities that are managed or operated under its contract with DOE. 
(2) It is the responsibility of the Contractor to obtain from its subcontractors technical data and computer software and rights therein, on behalf of the Government, necessary to fulfill the Contractor's obligations to the Government with respect to such data. In the event of refusal by a subcontractor to accept a clause affording the Government such rights, the Contractor shall: 
(i) Promptly submit written notice to the contracting officer setting forth reasons or the subcontractor's refusal and other pertinent information which may expedite disposition of the matter, and 
(ii) Not proceed with the subcontract without the written authorization of the contracting officer. 
(3) Neither the Contractor nor higher-tier subcontractors shall use their power to award subcontracts as economic leverage to acquire rights in a subcontractor's limited rights data or restricted computer software for their private use. 
(e) Rights in Limited Rights Data. Except as may be otherwise specified in this Contract as data which are not subject to this paragraph, the Contractor agrees to and does hereby grant to the Government an irrevocable, nonexclusive, paid-up license by or for the Government, in any limited rights data of the Contractor specifically used in the performance of this Contract, provided, however, that to the extent that any limited rights data when furnished or delivered is specifically identified by the Contractor at the time of initial delivery to the Government or a representative of the Government, such data shall not be used within or outside the Government except as provided in the “Limited Rights Notice” set forth. All such limited rights data shall be marked with the following “Limited Rights Notice”: 
Limited Rights Notice
These data contain “limited rights data,” furnished under Contract No. ________ with the United States Department of Energy which may be duplicated and used by the Government with the express limitations that the “limited rights data” may not be disclosed outside the Government or be used for purposes of manufacture without prior permission of the Contractor, except that further disclosure or use may be made solely for the following purposes: 
(a) Use (except for manufacture) by support services contractors within the scope of their contracts; 
(b) This “limited rights data” may be disclosed for evaluation purposes under the restriction that the “limited rights data” be retained in confidence and not be further disclosed; 
(c) This “limited rights data” may be disclosed to other contractors participating in the Government's program of which this Contract is a part for information or use (except for manufacture) in connection with the work performed under their contracts and under the restriction that the “limited rights data” be retained in confidence and not be further disclosed; 
(d) This “limited rights data” may be used by the Government or others on its behalf for emergency repair or overhaul work under the restriction that the “limited rights data” be retained in confidence and not be further disclosed; and 
(e) Release to a foreign government, or instrumentality thereof, as the interests of the United States Government may require, for information or evaluation, or for emergency repair or overhaul work by such government. This Notice shall be marked on any reproduction of this data in whole or in part. 
(End of notice) 
(f) Rights in restricted computer software. (1) Except as may be otherwise specified in this Contract as data which are not subject to this paragraph, the Contractor agrees to and does hereby grant to the Government an irrevocable, nonexclusive, paid-up, license by or for the Government, in any restricted computer software of the Contractor specifically used in the performance of this Contract, provided, however, that to the extent that any restricted computer software when furnished or delivered is specifically identified by the Contractor at the time of initial delivery to the Government or a representative of the Government, such data shall not be used within or outside the Government except as provided in the “Restricted Rights Notice” set forth below. All such restricted computer software shall be marked with the following “Restricted Rights Notice”: 
Restricted Rights Notice-Long Form 
(a) This computer software is submitted with restricted rights under Department of Energy Contract No. _______. It may not be used, reproduced, or disclosed by the Government except as provided in paragraph (b) of this notice. 
(b) This computer software may be: 
(1) Used or copied for use in or with the computer or computers for which it was acquired, including use at any Government installation to which such computer or computers may be transferred; 
(2) Used, copied for use, in a backup or replacement computer if any computer for which it was acquired is inoperative or is replaced; 
(3) Reproduced for safekeeping (archives) or backup purposes; 
(4) Modified, adapted, or combined with other computer software, provided that only the portions of the derivative software consisting of the restricted computer software are to be made subject to the same restricted rights; and 
(5) Disclosed to and reproduced for use by contractors under a service contract (of the type defined in 48 CFR 37.101) in accordance with subparagraphs (b)(1) through (4) of this Notice, provided the Government makes such disclosure or reproduction subject to these restricted rights. 
(c) Notwithstanding the foregoing, if this computer software has been published under copyright, it is licensed to the Government, without disclosure prohibitions, with the rights set forth in the restricted rights notice above. 
(d) This Notice shall be marked on any reproduction of this computer software, in whole or in part. 
(End of notice) 
(2) Where it is impractical to include the Restricted Rights Notice on restricted computer software, the following short-form Notice may be used. 
Restricted Rights Notice—Short Form 
Use, reproduction, or disclosure is subject to restrictions set forth in the Long Form Notice of DOE Contract No. _______ with (name of Contractor). 
(End of notice) 
(3) If the software is embedded, or if it is commercially impractical to mark it with human readable text, then the symbol R and the clause date (mo/yr), in brackets or a box, a [R-mo/yr], may be used. This will be read to mean restricted computer software, subject to the rights of the Government as described in the Long Form Notice, in effect as of the date indicated next to the symbol. The symbol shall not be used to mark human readable material. In the event this Contract contains any variation to the rights in the Long Form Notice, then the contract number must also be cited. 
(4) If restricted computer software is delivered with the copyright notice of 17 U.S.C. 401, the software will be presumed to be published copyrighted computer software licensed to the Government without disclosure prohibitions and with unlimited rights, unless the Contractor includes the following statement with such copyright notice “Unpublished-rights reserved under the Copyright Laws of the United States.” 
(g) Relationship to patents. Nothing contained in this clause creates or is intended to imply a license to the Government in any patent or is intended to be construed as affecting the scope of any licenses or other rights otherwise granted to the Government under any patent.

In addition to the above clauses, the following clauses apply to the award of the letter contracts

I.155  52.216-24 -- Limitation of Government Liability (Apr 1984)
(a) In performing this contract, the Contractor is not authorized to make expenditures or incur obligations exceeding $6,400,000.
(b) The maximum amount for which the Government shall be liable if this contract is terminated is $6,400,000.

I.156  52.216-25 -- Contract Definitization (Oct 2010)
(a) A cost-reimbursement cost share definitive contract is contemplated. The Contractor agrees to begin promptly negotiating with the Contracting Officer the terms of a definitive contract that will include (1) all clauses required by the Federal Acquisition Regulation (FAR) on the date of execution of the letter contract, (2) all clauses required by law on the date of execution of the definitive contract, and (3) any other mutually agreeable clauses, terms, and conditions. The Contractor agrees to submit a cost-no-fee with cost share proposal, including data other than certified cost or pricing data, and certified cost or pricing data, in accordance with FAR 15.408, Table 15-2, supporting its proposal.
(b) The schedule for definitizing this contract is October 31, 2019, including the following dates:
Submittal of proposal        May 23, 2019
Begin Negotiations        September 17 , 2019
(c) If agreement on a definitive contract to supersede this letter contract is not reached by the target date in paragraph (b) of this section, or within any extension of it granted by the Contracting Officer, the Contracting Officer may, with the approval of the head of the contracting activity, determine a reasonable price or fee in accordance with Subpart 15.4 and Part 31 of the FAR, subject to Contractor appeal as provided in the Disputes clause. In any event, the Contractor shall proceed with completion of the contract, subject only to the Limitation of Government Liability clause.
(1) After the Contracting Officer’s determination of price or fee, the contract shall be governed by --
(i) All clauses required by the FAR on the date of execution of this letter contract for either fixed-price or cost-reimbursement contracts, as determined by the Contracting Officer under this paragraph (c);
(ii) All clauses required by law as of the date of the Contracting Officer’s determination; and
(iii) Any other clauses, terms, and conditions mutually agreed upon.
(2) To the extent consistent with subparagraph (c)(1) of this section, all clauses, terms, and conditions included in this letter contract shall continue in effect, except those that by their nature apply only to a letter contract.

I.157  52.216-26 -- Payments of Allowable Costs Before Definitization (Dec. 2002)
(a) Reimbursement rate. Pending the placing of the definitive contract referred to in this letter contract, the Government will promptly reimburse the Contractor for all allowable costs under this contract at the following rates:
(1) One hundred percent of approved costs representing financing payments to subcontractors under fixed-price subcontracts; provided, that the Government’s payments to the Contractor will not exceed 80 percent of the allowable costs of those subcontractors.
(2) One hundred percent of approved costs representing cost-reimbursement subcontracts; provided, that the Government’s payments to the Contractor shall not exceed 85 percent of the allowable costs of those subcontractors.
(3) Eighty-five percent of all other approved costs.
(b) Limitation of reimbursement. To determine the amounts payable to the Contractor under this letter contract, the Contracting Officer shall determine allowable costs in accordance with the applicable cost principles in Part 31 of the Federal Acquisition Regulation (FAR). The total reimbursement made under this paragraph shall not exceed 85 percent of the maximum amount of the Government’s liability, as stated in this contract.
(c) Invoicing. Payments shall be made promptly to the Contractor when requested as work progresses, but (except for small business concerns) not more often than every 2 weeks, in amounts approved by the Contracting Officer. The Contractor may submit to an authorized representative of the Contracting Officer, in such form and reasonable detail as the representative may require, an invoice or voucher supported by a statement of the claimed allowable cost incurred by the Contractor in the performance of this contract.
(d) Allowable costs. For the purpose of determining allowable costs, the term “costs” includes --
(1) Those recorded costs that result, at the time of the request for reimbursement, from payment by cash, check, or other form of actual payment for items or services purchased directly for the contract;
(2) When the Contractor is not delinquent in payment of costs of contract performance in the ordinary course of business, costs incurred, but not necessarily paid, for –
(i) Supplies and services purchased directly for the contract and associated financing payments t subcontractors, provided payments determined due will be made--
(A) In accordance with the terms and conditions of a subcontract or invoice; and 
(B) Ordinarily within 30 days of the submission of the Contractor’s payment request to the Government;
(ii) Materials issued from the Contractor’s stores inventory and placed in the production process for use on the contract;
(iii) Direct labor;
(iv) Direct travel;
(v) Other direct in-house costs; and
(vi) Properly allocable and allowable indirect costs as shown on the records maintained by the Contractor for purposes of obtaining reimbursement under Government contracts; and
(3) The amount of financing payments that the Contractor has paid by cash, check, or other forms of payment to subcontractors.
(e) Small business concerns. A small business concern may receive more frequent payments than every 2 weeks.
(f) Audit. At any time before final payment, the Contracting Officer may have the Contractor’s invoices or vouchers and statements of costs audited. Any payment may be --
(1) Reduced by any amounts found by the Contracting Officer not to constitute allowable costs; or
(2) Adjusted for overpayments or underpayments made on preceding invoices or vouchers.

I.158  52.232-16 Progress Payments (Apr 2012)
The Government will make progress payments to the Contractor when requested as work progresses, but not more frequently than monthly in amounts of $2,500 or more approved by the Contracting Officer, under the following conditions:
(a) Computation of amounts.
(1) Unless the Contractor requests a smaller amount, the Government will compute each progress payment as 80 percent of the Contractor’s total costs incurred under this contract whether or not actually paid, plus financing payments to subcontractors (see paragraph (j) of this clause), less the sum of all previous progress payments made by the Government under this contract. The Contracting Officer will consider cost of money that would be allowable under FAR 31.205-10 as an incurred cost for progress payment purposes.
(2) The amount of financing and other payments for supplies and services purchased directly for the contract are limited to the amounts that have been paid by cash, check, or other forms of payment, or that are determined due will be paid to subcontractors--
(i) In accordance with the terms and conditions of a subcontract or invoice; and 
(ii) Ordinarily within 30 days of the submission of the Contractor’s payment request to the Government.
(3) The Government will exclude accrued costs of Contractor contributions under employee pension plans until actually paid unless--
(i) The Contractor’s practice is to make contributions to the retirement fund quarterly or more frequently; and 
(ii) The contribution does not remain unpaid 30 days after the end of the applicable quarter or shorter payment period (any contribution remaining unpaid shall be excluded from the Contractor’s total costs for progress payments until paid).
(4) The Contractor shall not include the following in total costs for progress payment purposes in paragraph (a)(1) of this clause:
(i) Costs that are not reasonable, allocable to this contract, and consistent with sound and generally accepted accounting principles and practices.
(ii) Costs incurred by subcontractors or suppliers.
(iii) Costs ordinarily capitalized and subject to depreciation or amortization except for the properly depreciated or amortized portion of such costs.
(iv) Payments made or amounts payable to the subcontractors or suppliers, except for--
(A) completed work, including partial deliveries, to which the Contractor has acquired title; and
(B) Work under cost-reimbursement or time-and-material subcontracts to which the Contractor has acquired title.
(5) The amount of unliquidated progress payments may exceed neither (i) the progress payments made against incomplete work (including allowable unliquidated progress payments to subcontractors) nor (ii) the value, for progress payment purposes, of the incomplete work. Incomplete work shall be considered to be the supplies and services required by this contract, for which delivery and invoicing by the Contractor and acceptance by the Government are incomplete.
(6) The total amount of progress payments shall not exceed 80 percent of the total contract price.
(7) If a progress payment or the unliquidated progress payments exceed the amounts permitted by subparagraphs (a)(4) or (a)(5) above, the Contractor shall repay the amount of such excess to the Government on demand.
(8) Notwithstanding any other terms of the contract, the Contractor agrees not to request progress payments in dollar amounts of less than $2,500. The Contracting Officer may make exceptions.
(9) The costs applicable to items delivered, invoiced, and accepted shall not include costs in excess of the contract price of the items.
(b) Liquidation. Except as provided in the Termination for Convenience of the Government clause, all progress payments shall be liquidated by deducting from any payment under this contract, other than advance or progress payments, the unliquidated progress payments, or 80 percent of the amount invoiced, whichever is less. The Contractor shall repay to the Government any amounts required by a retroactive price reduction, after computing liquidation’s and payments on past invoices at the reduced prices and adjusting the unliquidated progress payments accordingly. The Government reserves the right to unilaterally change from the ordinary liquidation rate to an alternate rate when deemed appropriate for proper contract financing.
(c) Reduction or suspension. The Contracting Officer may reduce or suspend progress payments, increase the rate of liquidation, or take a combination of these actions, after finding on substantial evidence any of the following conditions:
(1) The Contractor failed to comply with any material requirement of this contract (which includes paragraphs (f) and (g) below).
(2) Performance of this contract is endangered by the Contractor’s --
(i) Failure to make progress; or
(ii) Unsatisfactory financial condition.
(3) Inventory allocated to this contract substantially exceeds reasonable requirements.
(4) The Contractor is delinquent in payment of the costs of performing this contract in the ordinary course of business.
(5) The fair value of the undelivered work is less than the amount of unliquidated progress payments for that work.
(6) The Contractor is realizing less profit than that reflected in the establishment of any alternate liquidation rate in paragraph (b) above, and that rate is less than the progress payment rate stated in subparagraph (a)(1) above.
(d) Title.
(1) Title to the property described in this paragraph (d) shall vest in the Government. Vestiture shall be immediately upon the date of this contract, for property acquired or produced before that date. Otherwise, vestiture shall occur when the property is or should have been allocable or properly chargeable to this contract.
(2) “Property,” as used in this clause, includes all of the below-described items acquired or produced by the Contractor that are or should be allocable or properly chargeable to this contract under sound and generally accepted accounting principles and practices.
(i) Parts, materials, inventories, and work in process;
(ii) Special tooling and special test equipment to which the Government is to acquire title;
(iii) Nondurable (i.e., noncapital) tools, jigs, dies, fixtures, molds, patterns, taps, gauges, test equipment, and other similar manufacturing aids, title to which would not be obtained as special tooling under subparagraph (ii) above; and
(iv) Drawings and technical data, to the extent the Contractor or subcontractors are required to deliver them to the Government by other clauses of this contract.
(3) Although title to property is in the Government under this clause, other applicable clauses of this contract; e.g., the termination clauses, shall determine the handling and disposition of the property.
(4) The Contractor may sell any scrap resulting from production under this contract without requesting the Contracting Officer’s approval, but the proceeds shall be credited against the costs of performance.
(5) To acquire for its own use or dispose of property to which title is vested in the Government under this clause, the Contractor must obtain the Contracting Officer’s advance approval of the action and the terms. The Contractor shall
(i) exclude the allocable costs of the property from the costs of contract performance, and
(ii) repay to the Government any amount of unliquidated progress payments allocable to the property. Repayment may be by cash or credit memorandum.
(6) When the Contractor completes all of the obligations under this contract, including liquidation of all progress payments, title shall vest in the Contractor for all property (or the proceeds thereof) not --
(i) Delivered to, and accepted by, the Government under this contract; or
(ii) Incorporated in supplies delivered to, and accepted by, the Government under this contract and to which title is vested in the Government under this clause.
(7) The terms of this contract concerning liability for Government-furnished property shall not apply to property to which the Government acquired title solely under this clause.
(e) Risk of loss. Before delivery to and acceptance by the Government, the Contractor shall bear the risk of loss for property, the title to which vests in the Government under this clause, except to the extent the Government expressly assumes the risk. The Contractor shall repay the Government an amount equal to the unliquidated progress payments that are based on costs allocable to property that is lost (see 45.101). 
(f) Control of costs and property. The Contractor shall maintain an accounting system and controls adequate for the proper administration of this clause.
(g) Reports and access to records. 
(1) The Contractor shall promptly furnish reports, certificates, financial statements, and other pertinent information (including estimates to complete) reasonably requested by the Contracting Officer for the administration of this clause. Also, the Contractor shall give the Government reasonable opportunity to examine and verify the Contractor’s books, records, and accounts.
(2) The Contractor shall furnish estimates to complete that have been developed or updated within six months of the date of the progress payment request. The estimates to complete shall represent the Contractor’s best estimate of total costs to complete all remaining contract work required under the contract. The estimates shall include sufficient detail to permit Government verification.
(3) Each Contractor request for progress payment shall:
(i) Be submitted on Standard Form 1443, Contractor’s Request for Progress Payment, or the electronic equivalent as required by agency regulations, in accordance with the form instructions and the contract terms; and
(ii) Include any additional supporting documentation requested by the Contracting Officer.
(h) Special terms regarding default. If this contract is terminated under the Default clause,
(i) the Contractor shall, on demand, repay to the Government the amount of unliquidated progress payments and
(ii) title shall vest in the Contractor, on full liquidation of progress payments, for all property for which the Government elects not to require delivery under the Default clause. The Government shall be liable for no payment except as provided by the Default clause.
(i) Reservations of rights.
(1) No payment or vesting of title under this clause shall—
(i) Excuse the Contractor from performance of obligations under this contract; or
(ii) Constitute a waiver of any of the rights or remedies of the parties under the contract.
(2) The Government’s rights and remedies under this clause—
(i) Shall not be exclusive but rather shall be in addition to any other rights and remedies provided by law or this contract; and
(ii) Shall not be affected by delayed, partial, or omitted exercise of any right, remedy, power, or privilege, nor shall such exercise or any single exercise preclude or impair any further exercise under this clause or the exercise of any other right, power, or privilege of the Government.
(j) Financing payments to subcontractors. The financing payments to subcontractors mentioned in paragraphs (a)(1) and (a)(2) of this clause shall be all financing payments to subcontractors or divisions, if the following conditions are met:
(1) The amounts included are limited to—
(i) The unliquidated remainder of financing payments made; plus
(ii) Any unpaid subcontractor requests for financing payments.
(2) The subcontract or interdivisional order is expected to involve a minimum of approximately 6 months between the beginning of work and the first delivery, or, if the subcontractor is a small business concern, 4 months.
(3) If the financing payments are in the form or progress payments, the terms of the subcontract or interdivisional order concerning progress payments --
(i) Are substantially similar to the terms of the clause for any subcontractor that is a large business concern, or that clause with its Alternate I for any subcontractor that is a small business concern;
(ii) Are at least as favorable to the Government as the terms of this clause;
(iii) Are not more favorable to the subcontractor or division than the terms of this clause are to the Contractor;
(iv) Are in conformance with the requirements of FAR 32.504(e); and
(v) Subordinate all subcontractor rights concerning property to which the Government has title under the subcontract to the Government’s right to require delivery of the property to the Government if --
(A) The Contractor defaults; or
(B) The subcontractor becomes bankrupt or insolvent.
(4) If the financing payments are in the form of performance-based payments, the terms of the subcontract or interdivisional order concerning payments—
(i) Are substantially similar to the Performance-Based Payments clause at FAR 52.232-32 and meet the criteria for, and definition of, performance-based payments in FAR Part 32;
(ii) Are in conformance with the requirements of FAR 32.504(f); and
(iii) Subordinate all subcontractor rights concerning property to which the Government has title under the subcontract to the Government’s right to require delivery of the property to the Government if—
(A) The Contractor defaults; or
(B) The subcontractor becomes bankrupt or insolvent.
(5) If the financing payments are in the form of commercial item financing payments, the terms of the subcontract or interdivisional order concerning payments—
(i) Are constructed in accordance with FAR 32.206(c) and included in a subcontract for a commercial item purchase that meets the definition and standards for acquisition of commercial items in FAR Part 2 and 12;
(ii) Are in conformance with the requirements of FAR 32.504(g); and
(iii) Subordinate all subcontractor rights concerning property to which the Government has title under the subcontract to the Government’s right to require delivery of the property to the Government if—
(A) The Contractor defaults; or
(B) The subcontractor becomes bankrupt or insolvent.
(6) If financing is in the form of progress payments, the progress payment rate in the subcontract is the customary rate used by the contracting agency, depending on whether the subcontractor is or is not a small business concern.
(7) Concerning any proceeds received by the Government for property to which title has vested in the Government under the subcontract terms, the parties agree that the proceeds shall be applied to reducing any unliquidated financing payments by the Government to the Contractor under this contract.
(8) If no unliquidated financing payments to the Contractor remain, but there are unliquidated financing payments that the Contractor has made to any subcontractor, the Contractor shall be subrogated to all the rights the Government obtained through the terms required by this clause to be in any subcontract, as if all such rights had been assigned and transferred to the Contractor.
(9) To facilitate small business participation in subcontracting under this contract, the Contractor shall provide financing payments to small business concerns, in conformity with the standards for customary contract financing payments stated in Subpart 32.113. The Contractor shall not consider the need for such financing payments as a handicap or adverse factor in the award of subcontracts.
(k) Limitations on undefinitized contract actions. Notwithstanding any other progress payment provisions in this contract, progress payments may not exceed 80 percent of costs incurred on work accomplished under undefinitized contract actions. A “contract action” is any action resulting in a contract, as defined in Subpart 2.1, including contract modifications for additional supplies or services, but not including contract modifications that are within the scope and under the terms of the contract, such as contract modifications issued pursuant to the Changes clause, or funding and other administrative changes. This limitation shall apply to the costs incurred, as computed in accordance with paragraph (a) of this clause, and shall remain in effect until the contract action is definitized. Costs incurred which are subject to this limitation shall be segregated on Contractor progress payment requests and invoices from those costs eligible for higher progress payment rates. For purposes of progress payment liquidation, as described in paragraph (b) of this clause, progress payments for undefinitized contract actions shall be liquidated at 80 percent of the amount invoiced for work performed under the undefinitized contract action as long as the contract action remains undefinitized. The amount of unliquidated progress payments for undefinitized contract actions shall not exceed 80 percent of the maximum liability of the Government under the undefinitized contract action or such lower limit specified elsewhere in the contract. Separate limits may be specified for separate actions.
(l) Due date. The designated payment office will make progress payments on the 30thday after the designated billing office receives a proper progress payment request. In the event that the Government requires an audit or other review of a specific progress payment request to ensure compliance with the terms and conditions of the contract, the designated payment office is not compelled to make a payment by the specified due date. Progress payments are considered contract financing and are not subject to the interest penalty provisions of the Prompt Payment Act.
(m) Progress payments under indefinite-delivery contracts. The Contractor shall account for and submit progress payment requests under individual orders as if the order constituted a separate contract, unless otherwise specified in this contract.
(n) The Contracting Officer will liquidate progress payments made under this letter contract, unless previously liquidated under paragraph (b) of this clause, using the following procedures:
(1) If this letter contract is superseded by a definitive contract, unliquidated progress payments made under this letter contract shall be liquidated by deducting the amount from the first progress or other payments made under the definitive contract.
(2) If this letter contract is not superseded by a definitive contract calling for the furnishing of all or part of the articles or services covered under the letter contract, unliquidated progress payments made under the letter contract shall be liquidated by deduction from the amount payable under the Termination clause.
(3) If this letter contract is partly terminated and partly superseded by a contract, the Government will allocate the unliquidated progress payments to the terminated and unterminated portions as the Government deems equitable, and will liquidate each portion under the relevant procedure in paragraphs (n)(1) and (n)(2) of this clause.
(4) If the method of liquidating progress payments provided in this clause does not result in full liquidation, the Contractor shall immediately pay the unliquidated balance to the Government on demand.
(o) The amount of unliquidated progress payments shall not exceed $11,000,000.

Section J - List of Documents, Exhibits and Other Attachments

DOE-J-1001 List of Attachments 
The following attachments constitute part of this contract:

	
		
	Attachment
	Description

	1
	Compliance Documents

	2
	Contractor-Furnished Equipment

	3
	Wage Rate Determinations

	4
	Government-Furnished Property

	5
	Reporting Requirements

SECTION J - ATTACHMENT 1
COMPLIANCE DOCUMENTS

List A - Laws, Regulations, and DOE Directives

DOE is providing a list of laws and regulations (List A) applicable to work performed under this contract. Unless relief has been granted in writing by the appropriate regulatory agency, the Contractor shall comply with all applicable Federal and State Laws, Statutes, Codes, Rules, Regulations, and Orders; Executive Orders; Consensus Standards; and agreement documents applicable to work performed under this contract.  The federal laws and regulations listed in the table below contain requirements normally relevant to the Contractor scope of work.  These laws and regulations, and others, apply regardless whether they are explicitly stated in the Contract.  In addition, laws and regulations typically apply to all persons or organizations such as subcontractors, suppliers, and federal employees.

Omission of any such applicable law or regulation in from List A does not affect the obligation of the Contractor to comply with such law or regulation. The Contractor must be aware of changes in the Code of Federal Regulations (CFR), Federal Acquisition Regulations (FAR), the United States Code (USC), Public Laws (PL) or other regulatory entities that have applicability to the Department of Energy and that impact the work scope.  The Contractor shall notify the DOE Contracting Officer of any changes, and DOE will make a determination regarding modification to the contract. 

	
		
	10 CFR 719
	Contractor Legal Management Requirements

	36 CFR Chapter XII
	National Archives and Records Administration

	41 CFR 109
	Department of Energy Property Management Regulations

List B - Applicable DOE Directives and Compliance Documents

The Contractor shall comply with the conditions and requirements of the NRC Nuclear Materials License SNM-7003 and applicable regulations 
The Contracting Officer may, from time to time and at any time, revise List B by unilateral modification to the contract to add, modify, or delete specific requirements. Prior to revising List B, the Contracting Officer shall notify the Contractor in writing of the Department's intent to revise List B and provide the Contractor with the opportunity to assess the effect of the Contractor's compliance with the revised list on contract cost and funding, technical performance, and schedule; and identify any potential inconsistencies between the revised list and the other terms and conditions of the contract or NRC License. Based on the information provided by the Contractor and any other information available, the Contracting Officer shall decide whether to revise List B and so advise the Contractor not later than 30 days prior to the effective date of the revision of List B. The Contractor and the Contracting Officer shall identify and, if appropriate, agree to any changes to other contract terms and conditions, including cost and schedule, associated with the revision of List B pursuant to the clause of this contract entitled, “Changes.” 
The Contractor is responsible for flowing down the requirements of these requirements to subcontracts at any tier to the extent necessary to ensure the Contractor's compliance with the requirements.

DOE Directives included in the Access Permit 11-04:AC Operating, are incorporated by reference into the Contract.   

	
			
	Directive
	Title

	 
	DOE O 142.3A
	Unclassified Foreign Visits and Assignments Program

	 
	DOE O 206.1
	DOE Privacy Program

	DOE N 206.4
	Personal Identity Verification

	 
	DOE O 210.2A
	DOE Corporate Operating Experience Program

	 
	DOE O 221.2A
	Cooperation with the Office of Inspector General

	 
	DOE O 243.1B, Admin Change 1
	Records Management Program

	 
	DOE O 442.1A
	Department of Energy Employee Concerns Program

	 
	DOE O 442.2
	Differing Professional Opinions for Technical Issues Involving Environment, Safety and Health

	 
	DOE O 451.1B, Admin Change 3
	National Environmental Policy Act Compliance Program

	 
	DOE O 460.1D
	Packaging and Transportation Safety

	DOE Order 460.2A
	Departmental Materials Transportation and Packaging Management

	DOE-STD-1186-2004
	Specific Administrative Controls

    

To Be Added

WD 15-4643 (Rev.-10) was first posted on www.wdol.gov on 01/01/2019
************************************************************************************
REGISTER OF WAGE DETERMINATIONS UNDER  |        U.S. DEPARTMENT OF LABOR
       THE SERVICE CONTRACT ACT        |  EMPLOYMENT STANDARDS ADMINISTRATION
By direction of the Secretary of Labor |         WAGE AND HOUR DIVISION
                                       |         WASHINGTON D.C.  20210
                                       |
                                       |
                                       |
                                       | Wage Determination No.: 2015-4643
Daniel W. Simms          Division of   |           Revision No.: 10
Director            Wage Determinations|       Date Of Revision: 12/26/2018
_______________________________________|____________________________________________
Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.60 for
calendar year 2019 applies to all contracts subject to the Service Contract
Act for which the contract is awarded (and any solicitation was issued) on or
after January 1, 2015. If this contract is covered by the EO, the contractor
must pay all workers in any classification listed on this wage determination
at least $10.60 per hour (or the applicable wage rate listed on this wage
determination, if it is higher) for all hours spent performing on the contract
in calendar year 2019. The EO minimum wage rate will be adjusted annually.
Additional information on contractor requirements and worker protections under
the EO is available at www.dol.gov/whd/govcontracts.
____________________________________________________________________________________
State: Tennessee

Area: Tennessee Counties of Anderson, Blount, Campbell, Grainger, Knox, Loudon,
 Morgan, Roane, Union
____________________________________________________________________________________
          **Fringe Benefits Required Follow the Occupational Listing**
OCCUPATION CODE - TITLE                                  FOOTNOTE               RATE
01000 - Administrative Support And Clerical Occupations
  01011 - Accounting Clerk I                             13.97
  01012 - Accounting Clerk II                            15.68
  01013 - Accounting Clerk III                           17.54
  01020 - Administrative Assistant                       23.47
  01035 - Court Reporter                                 18.10
  01041 - Customer Service Representative I              11.55
  01042 - Customer Service Representative II             12.99
  01043 - Customer Service Representative III            14.17
  01051 - Data Entry Operator I                          12.67
  01052 - Data Entry Operator II                         13.82
  01060 - Dispatcher, Motor Vehicle                      17.17
  01070 - Document Preparation Clerk                     13.97
  01090 - Duplicating Machine Operator                    13.97
  01111 - General Clerk I                                 11.97
  01112 - General Clerk II                                13.06
  01113 - General Clerk III                               14.66
  01120 - Housing Referral Assistant                      19.92
  01141 - Messenger Courier                               12.88
  01191 - Order Clerk I                                   14.36
  01192 - Order Clerk II                                  16.52
  01261 - Personnel Assistant (Employment) I              15.13
  01262 - Personnel Assistant (Employment) II             16.92
  01263 - Personnel Assistant (Employment) III            18.87
  01270 - Production Control Clerk                        24.30
  01290 - Rental Clerk                                    13.05
  01300 - Scheduler, Maintenance                       16.31
  01311 - Secretary I                                     16.31
  01312 - Secretary II                                    18.10
  01313 - Secretary III                                   19.92
  01320 - Service Order Dispatcher                        17.05
  01410 - Supply Technician                               23.47
  01420 - Survey Worker                                   17.19
  01460 - Switchboard Operator/Receptionist               12.97
  01531 - Travel Clerk I                                  14.28
  01532 - Travel Clerk II                                 15.20
  01533 - Travel Clerk III                                16.37
  01611 - Word Processor I                                13.56
  01612 - Word Processor II                               15.22
  01613 - Word Processor III                              17.03
05000 - Automotive Service Occupations
  05005 - Automobile Body Repairer, Fiberglass            19.72
  05010 - Automotive Electrician                          16.26
  05040 - Automotive Glass Installer                      15.46
  05070 - Automotive Worker                               15.46
  05110 - Mobile Equipment Servicer                       13.68
  05130 - Motor Equipment Metal Mechanic                  17.13
  05160 - Motor Equipment Metal Worker                    15.46
  05190 - Motor Vehicle Mechanic                          17.13
  05220 - Motor Vehicle Mechanic Helper                   13.06
  05250 - Motor Vehicle Upholstery Worker                 14.51
  05280 - Motor Vehicle Wrecker                           15.46
  05310 - Painter, Automotive                             18.18
  05340 - Radiator Repair Specialist                      15.46
  05370 - Tire Repairer                                   14.67
  05400 - Transmission Repair Specialist                  17.13
07000 - Food Preparation And Service Occupations
  07010 - Baker                                           12.00
  07041 - Cook I                                          11.36
  07042 - Cook II                                         12.84
  07070 - Dishwasher                                       9.00
  07130 - Food Service Worker                              9.61
  07210 - Meat Cutter                                     14.13
  07260 - Waiter/Waitress                                  8.86
09000 - Furniture Maintenance And Repair Occupations
  09010 - Electrostatic Spray Painter                     17.03
  09040 - Furniture Handler                               11.85
  09080 - Furniture Refinisher                            17.03
  09090 - Furniture Refinisher Helper                     13.76
  09110 - Furniture Repairer, Minor                        15.32
  09130 - Upholsterer                                      17.03
11000 - General Services And Support Occupations
  11030 - Cleaner, Vehicles                                10.48
  11060 - Elevator Operator                                11.25
  11090 - Gardener                                         15.74
  11122 - Housekeeping Aide                                11.25
  11150 - Janitor                                          11.25
  11210 - Laborer, Grounds Maintenance                     12.47
  11240 - Maid or Houseman                                  9.10
  11260 - Pruner                                           11.30
  11270 - Tractor Operator                                 14.75
  11330 - Trail Maintenance Worker                         12.47
  11360 - Window Cleaner                                   12.03
12000 - Health Occupations
  12010 - Ambulance Driver                                 14.54
  12011 - Breath Alcohol Technician                        16.48
  12012 - Certified Occupational Therapist Assistant       28.33
  12015 - Certified Physical Therapist Assistant           25.92
  12020 - Dental Assistant                                 18.58
  12025 - Dental Hygienist                                 36.27
  12030 - EKG Technician                                   24.08
  12035 - Electroneurodiagnostic Technologist              24.08
  12040 - Emergency Medical Technician                     14.54
  12071 - Licensed Practical Nurse I                       15.62
  12072 - Licensed Practical Nurse II                      17.47
  12073 - Licensed Practical Nurse III                     19.47
  12100 - Medical Assistant                                14.77
  12130 - Medical Laboratory Technician                    16.69
  12160 - Medical Record Clerk                             15.35
  12190 - Medical Record Technician                        17.19
  12195 - Medical Transcriptionist                         15.79
  12210 - Nuclear Medicine Technologist                    30.63
  12221 - Nursing Assistant I                              11.51
  12222 - Nursing Assistant II                             12.95
  12223 - Nursing Assistant III                            14.13
  12224 - Nursing Assistant IV                             15.86
  12235 - Optical Dispenser                                17.66
  12236 - Optical Technician                               14.46
  12250 - Pharmacy Technician                              16.23
  12280 - Phlebotomist                                     14.69
  12305 - Radiologic Technologist                          23.63
  12311 - Registered Nurse I                               22.82
  12312 - Registered Nurse II                              27.91
  12313 - Registered Nurse II, Specialist                  27.91
  12314 - Registered Nurse III                             31.59
  12315 - Registered Nurse III, Anesthetist                31.59
  12316 - Registered Nurse IV                              39.18
  12317 - Scheduler (Drug and Alcohol Testing)             20.36
  12320 - Substance Abuse Treatment Counselor              18.59
13000 - Information And Arts Occupations
  13011 - Exhibits Specialist I                            17.69
  13012 - Exhibits Specialist II                           21.90
  13013 - Exhibits Specialist III                          26.79
  13041 - Illustrator I                                    17.69
  13042 - Illustrator II                                   21.90
  13043 - Illustrator III                                   26.79
  13047 - Librarian                                         24.26
  13050 - Library Aide/Clerk                                13.06
  13054 - Library Information Technology Systems            21.90
  Administrator
  13058 - Library Technician                                14.96
  13061 - Media Specialist I                                15.60
  13062 - Media Specialist II                               17.45
  13063 - Media Specialist III                              19.45
  13071 - Photographer I                                    15.35
  13072 - Photographer II                                   17.17
  13073 - Photographer III                                  21.27
  13074 - Photographer IV                                   26.03
  13075 - Photographer V                                    31.48
  13090 - Technical Order Library Clerk                     16.40
  13110 - Video Teleconference Technician                   20.03
14000 - Information Technology Occupations
  14041 - Computer Operator I                               15.77
  14042 - Computer Operator II                              17.64
  14043 - Computer Operator III                             19.67
  14044 - Computer Operator IV                              21.86
  14045 - Computer Operator V                               24.20
  14071 - Computer Programmer I       (see 1)               22.54
  14072 - Computer Programmer II      (see 1)               25.40
  14073 - Computer Programmer III     (see 1)
  14074 - Computer Programmer IV      (see 1)
  14101 - Computer Systems Analyst I   (see 1)
  14102 - Computer Systems Analyst II   (see 1)
  14103 - Computer Systems Analyst III  (see 1)
  14150 - Peripheral Equipment Operator                     15.77
  14160 - Personal Computer Support Technician              21.86
  14170 - System Support Specialist                         26.75
15000 - Instructional Occupations
  15010 - Aircrew Training Devices Instructor (Non-Rated)   28.52
  15020 - Aircrew Training Devices Instructor (Rated)       34.53
  15030 - Air Crew Training Devices Instructor (Pilot)      38.44
  15050 - Computer Based Training Specialist / Instructor   28.52
  15060 - Educational Technologist                          29.04
  15070 - Flight Instructor (Pilot)                         38.44
  15080 - Graphic Artist                                    22.66
  15085 - Maintenance Test Pilot, Fixed, Jet/Prop           38.44
  15086 - Maintenance Test Pilot, Rotary Wing               38.44
  15088 - Non-Maintenance Test/Co-Pilot                     38.44
  15090 - Technical Instructor                              21.69
  15095 - Technical Instructor/Course Developer             26.53
  15110 - Test Proctor                                      17.51
  15120 - Tutor                                             17.51
16000 - Laundry, Dry-Cleaning, Pressing And Related Occupations
  16010 - Assembler                                         10.00
  16030 - Counter Attendant                                 10.00
  16040 - Dry Cleaner                                       12.85
  16070 - Finisher, Flatwork, Machine                       10.00
  16090 - Presser, Hand                                     10.00
  16110 - Presser, Machine, Drycleaning                     10.00
  16130 - Presser, Machine, Shirts                          10.00
  16160 - Presser, Machine, Wearing Apparel, Laundry        10.00
  16190 - Sewing Machine Operator                            13.75
  16220 - Tailor                                             14.65
  16250 - Washer, Machine                                    11.04
19000 - Machine Tool Operation And Repair Occupations
  19010 - Machine-Tool Operator (Tool Room)                  20.01
  19040 - Tool And Die Maker                                 23.90
21000 - Materials Handling And Packing Occupations
  21020 - Forklift Operator                                  14.15
  21030 - Material Coordinator                               24.30
  21040 - Material Expediter                                 24.30
  21050 - Material Handling Laborer                          12.62
  21071 - Order Filler                                       11.78
  21080 - Production Line Worker (Food Processing)           14.15
  21110 - Shipping Packer                                    13.39
  21130 - Shipping/Receiving Clerk                           13.39
  21140 - Store Worker I                                     12.65
  21150 - Stock Clerk                                        17.12
  21210 - Tools And Parts Attendant                          14.15
  21410 - Warehouse Specialist                               14.15
23000 - Mechanics And Maintenance And Repair Occupations
  23010 - Aerospace Structural Welder                        25.29
  23019 - Aircraft Logs and Records Technician               20.45
  23021 - Aircraft Mechanic I                                24.12
  23022 - Aircraft Mechanic II                               25.29
  23023 - Aircraft Mechanic III                              26.37
  23040 - Aircraft Mechanic Helper                           18.06
  23050 - Aircraft, Painter                                  22.90
  23060 - Aircraft Servicer                                  20.45
  23070 - Aircraft Survival Flight Equipment Technician      22.90
  23080 - Aircraft Worker                                    21.78
  23091 - Aircrew Life Support Equipment (ALSE) Mechanic     21.78  I
  23092 - Aircrew Life Support Equipment (ALSE) Mechanic     24.12  II
  23110 - Appliance Mechanic                                 19.18
  23120 - Bicycle Repairer                                   17.01
  23125 - Cable Splicer                                      29.52
  23130 - Carpenter, Maintenance                             17.32
  23140 - Carpet Layer                                       20.98
  23160 - Electrician, Maintenance                           22.58
  23181 - Electronics Technician Maintenance I               23.10
  23182 - Electronics Technician Maintenance II              24.29
  23183 - Electronics Technician Maintenance III             25.60
  23260 - Fabric Worker                                      19.69
  23290 - Fire Alarm System Mechanic                         21.78
  23310 - Fire Extinguisher Repairer                         18.57
  23311 - Fuel Distribution System Mechanic                  25.61
  23312 - Fuel Distribution System Operator                  20.45
  23370 - General Maintenance Worker                         17.68
  23380 - Ground Support Equipment Mechanic                  24.12
  23381 - Ground Support Equipment Servicer                  20.45
  23382 - Ground Support Equipment Worker                    21.78
  23391 - Gunsmith I                                         18.57
  23392 - Gunsmith II                                        20.98
  23393 - Gunsmith III                                       23.25
  23410 - Heating, Ventilation And Air-Conditioning          20.40
  Mechanic
  23411 - Heating, Ventilation And Air Conditioning          21.47
  Mechanic (Research Facility)
  23430 - Heavy Equipment Mechanic                             23.08
  23440 - Heavy Equipment Operator                             18.30
  23460 - Instrument Mechanic                                  24.83
  23465 - Laboratory/Shelter Mechanic                          22.07
  23470 - Laborer                                              12.59
  23510 - Locksmith                                            22.07
  23530 - Machinery Maintenance Mechanic                       24.05
  23550 - Machinist, Maintenance                               22.16
  23580 - Maintenance Trades Helper                            13.60
  23591 - Metrology Technician I                               24.83
  23592 - Metrology Technician II                              26.13
  23593 - Metrology Technician III                             27.37
  23640 - Millwright                                           21.30
  23710 - Office Appliance Repairer                            18.25
  23760 - Painter, Maintenance                                 17.03
  23790 - Pipefitter, Maintenance                              21.31
  23810 - Plumber, Maintenance                                 20.22
  23820 - Pneudraulic Systems Mechanic                         23.25
  23850 - Rigger                                               21.92
  23870 - Scale Mechanic                                       20.98
  23890 - Sheet-Metal Worker, Maintenance                      21.46
  23910 - Small Engine Mechanic                                16.19
  23931 - Telecommunications Mechanic I                        24.51
  23932 - Telecommunications Mechanic II                       25.71
  23950 - Telephone Lineman                                    24.21
  23960 - Welder, Combination, Maintenance                     18.20
  23965 - Well Driller                                         23.25
  23970 - Woodcraft Worker                                     23.25
  23980 - Woodworker                                           18.57
24000 - Personal Needs Occupations
  24550 - Case Manager                                         14.30
  24570 - Child Care Attendant                                  9.61
  24580 - Child Care Center Clerk                              11.97
  24610 - Chore Aide                                           10.00
  24620 - Family Readiness And Support Services                14.30
  Coordinator
  24630 - Homemaker                                            14.87
25000 - Plant And System Operations Occupations
  25010 - Boiler Tender                                        25.65
  25040 - Sewage Plant Operator                                21.24
  25070 - Stationary Engineer                                  25.65
  25190 - Ventilation Equipment Tender                         18.46
  25210 - Water Treatment Plant Operator                       21.24
27000 - Protective Service Occupations
  27004 - Alarm Monitor                                        16.38
  27007 - Baggage Inspector                                    13.28
  27008 - Corrections Officer                                  15.46
  27010 - Court Security Officer                               18.42
  27030 - Detection Dog Handler                                15.32
  27040 - Detention Officer                                    15.46
  27070 - Firefighter                                          20.04
  27101 - Guard I                                              13.28
  27102 - Guard II                                             15.32
  27131 - Police Officer I                                     19.75
  27132 - Police Officer II                                    21.94
28000 - Recreation Occupations
  28041 - Carnival Equipment Operator                          12.70
  28042 - Carnival Equipment Repairer                          13.54
  28043 - Carnival Worker                                       9.73
  28210 - Gate Attendant/Gate Tender                           13.69
  28310 - Lifeguard                                            11.12
  28350 - Park Attendant (Aide)                                15.32
  28510 - Recreation Aide/Health Facility Attendant            11.18
  28515 - Recreation Specialist                                18.97
  28630 - Sports Official                                      12.19
  28690 - Swimming Pool Operator                               16.24
29000 - Stevedoring/Longshoremen Occupational Services
  29010 - Blocker And Bracer                                   23.61
  29020 - Hatch Tender                                         23.61
  29030 - Line Handler                                         23.61
  29041 - Stevedore I                                          22.17
  29042 - Stevedore II                                         24.83
30000 - Technical Occupations
  30010 - Air Traffic Control Specialist, Center (HFO)   (see 2)               38.15
  30011 - Air Traffic Control Specialist, Station (HFO)  (see 2)               26.30
  30012 - Air Traffic Control Specialist, Terminal (HFO) (see 2)               28.97
  30021 - Archeological Technician I                           17.11
  30022 - Archeological Technician II                          17.58
  30023 - Archeological Technician III                         21.62
  30030 - Cartographic Technician                              23.50
  30040 - Civil Engineering Technician                         22.23
  30051 - Cryogenic Technician I                               24.57
  30052 - Cryogenic Technician II                              27.14
  30061 - Drafter/CAD Operator I                               15.66
  30062 - Drafter/CAD Operator II                              17.58
  30063 - Drafter/CAD Operator III                             21.02
  30064 - Drafter/CAD Operator IV                              26.04
  30081 - Engineering Technician I                             15.84
  30082 - Engineering Technician II                            17.79
  30083 - Engineering Technician III                           20.11
  30084 - Engineering Technician IV                            24.92
  30085 - Engineering Technician V                             30.15
  30086 - Engineering Technician VI                            36.50
  30090 - Environmental Technician                             27.69
  30095 - Evidence Control Specialist                          20.76
  30210 - Laboratory Technician                                21.20
  30221 - Latent Fingerprint Technician I                      24.78
  30222 - Latent Fingerprint Technician II                     27.37
  30240 - Mathematical Technician                              21.56
  30361 - Paralegal/Legal Assistant I                          17.68
  30362 - Paralegal/Legal Assistant II                         21.89
  30363 - Paralegal/Legal Assistant III                        26.77
  30364 - Paralegal/Legal Assistant IV                         32.40
  30375 - Petroleum Supply Specialist                          25.42
  30390 - Photo-Optics Technician                              22.28
  30395 - Radiation Control Technician                         25.42
  30461 - Technical Writer I                                   20.66
  30462 - Technical Writer II                                  25.28
  30463 - Technical Writer III                                 30.58
  30491 - Unexploded Ordnance (UXO) Technician I               24.24
  30492 - Unexploded Ordnance (UXO) Technician II              29.33
  30493 - Unexploded Ordnance (UXO) Technician III             35.16
  30494 - Unexploded (UXO) Safety Escort                       24.24
  30495 - Unexploded (UXO) Sweep Personnel                     24.24
  30501 - Weather Forecaster I                                 24.57
  30502 - Weather Forecaster II                                29.88
  30620 - Weather Observer, Combined Upper Air Or        (see 2)               21.02
  Surface Programs
  30621 - Weather Observer, Senior                       (see 2)               22.04
31000 - Transportation/Mobile Equipment Operation Occupations
  31010 - Airplane Pilot                                        29.33
  31020 - Bus Aide                                              11.76
  31030 - Bus Driver                                            16.52
  31043 - Driver Courier                                        15.57
  31260 - Parking and Lot Attendant                             10.30
  31290 - Shuttle Bus Driver                                    16.60
  31310 - Taxi Driver                                           11.14
  31361 - Truckdriver, Light                                    16.60
  31362 - Truckdriver, Medium                                   17.62
  31363 - Truckdriver, Heavy                                    19.83
  31364 - Truckdriver, Tractor-Trailer                          19.83
99000 - Miscellaneous Occupations
  99020 - Cabin Safety Specialist                               14.30
  99030 - Cashier                                                9.65
  99050 - Desk Clerk                                            10.96
  99095 - Embalmer                                              25.37
  99130 - Flight Follower                                       24.24
  99251 - Laboratory Animal Caretaker I                         11.14
  99252 - Laboratory Animal Caretaker II                        13.06
  99260 - Marketing Analyst                                     25.29
  99310 - Mortician                                             25.37
  99410 - Pest Controller                                       19.18
  99510 - Photofinishing Worker                                 12.75
  99710 - Recycling Laborer                                     14.64
  99711 - Recycling Specialist                                  17.31
  99730 - Refuse Collector                                      13.25
  99810 - Sales Clerk                                           11.51
  99820 - School Crossing Guard                                 13.38
  99830 - Survey Party Chief                                    22.65
  99831 - Surveying Aide                                        15.00
  99832 - Surveying Technician                                  20.59
  99840 - Vending Machine Attendant                             14.69
  99841 - Vending Machine Repairer                              17.66
  99842 - Vending Machine Repairer Helper                       14.69

____________________________________________________________________________________
Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal
Contractors, applies to all contracts subject to the Service Contract Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017.  If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year. Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is the victim of, domestic violence, sexual assault, or stalking.  Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

ALL OCCUPATIONS LISTED ABOVE RECEIVE THE FOLLOWING BENEFITS:

HEALTH & WELFARE: $4.48 per hour or $179.20 per week or $776.53 per month

HEALTH & WELFARE EO 13706: $4.18 per hour, or $167.20 per week, or $724.53 per month*

*This rate is to be used only when compensating employees for performance on an SCA-covered contract also covered by EO 13706, Establishing Paid Sick Leave for Federal Contractors.  A contractor may not receive credit toward its SCA obligations for any paid sick leave provided pursuant to EO 13706.

VACATION: 2 weeks paid vacation after 1 year of service with a contractor or
successor, 3 weeks after 5 years, and 4 weeks after 15 years.  Length of service includes the whole span of continuous service with the present contractor or successor, wherever employed, and with the predecessor contractors in the performance of similar work at the same Federal facility.  (Reg. 29 CFR 4.173)

HOLIDAYS: A minimum of ten paid holidays per year:  New Year's Day, Martin Luther King Jr.'s Birthday, Washington's Birthday, Memorial Day, Independence Day, Labor Day, Columbus Day, Veterans' Day, Thanksgiving Day, and Christmas Day. (A contractor may substitute for any of the named holidays another day off with pay in accordance with a plan communicated to the employees involved.)  (See 29 CFR 4.174)

THE OCCUPATIONS WHICH HAVE NUMBERED FOOTNOTES IN PARENTHESES RECEIVE THE FOLLOWING:

1)  COMPUTER EMPLOYEES:  Under the SCA at section 8(b), this wage determination does not apply to any employee who individually qualifies as a bona fide executive, administrative, or professional employee as defined in 29 C.F.R. Part 541.  Because most Computer System Analysts and Computer Programmers who are compensated at a rate not less than $27.63 (or on a salary or fee basis at a rate not less than $455 per week) an hour would likely qualify as exempt computer professionals, (29 C.F.R. 541.
400) wage rates may not be listed on this wage determination for all occupations within those job families.  In addition, because this wage determination may not list a wage rate for some or all occupations within those job families if the survey data indicates that the prevailing wage rate for the occupation equals or exceeds $27.63 per hour conformances may be necessary for certain nonexempt employees.  For example, if an individual employee is nonexempt but nevertheless performs duties within the scope of one of the Computer Systems Analyst or Computer Programmer occupations for which this wage determination does not specify an SCA wage rate, then the wage rate for that employee must be conformed in accordance with the conformance procedures described in the conformance note included on this wage determination.

Additionally, because job titles vary widely and change quickly in the computer industry, job titles are not determinative of the application of the computer professional exemption.  Therefore, the exemption applies only to computer employees who satisfy the compensation requirements and whose primary duty consists of:
    (1) The application of systems analysis techniques and procedures, including consulting with users, to determine hardware, software or system functional specifications;
    (2) The design, development, documentation, analysis, creation, testing or modification of computer systems or programs, including prototypes, based on and related to user or system design specifications;
    (3) The design, documentation, testing, creation or modification of computer programs related to machine operating systems; or
    (4) A combination of the aforementioned duties, the performance of which
requires the same level of skills.  (29 C.F.R. 541.400).

2)  AIR TRAFFIC CONTROLLERS AND WEATHER OBSERVERS - NIGHT PAY & SUNDAY PAY:  If you work at night as part of a regular tour of duty, you will earn a night differential and receive an additional 10% of basic pay for any hours worked between 6pm and 6am.
 If you are a full-time employed (40 hours a week) and Sunday is part of your
regularly scheduled workweek, you are paid at your rate of basic pay plus a Sunday premium of 25% of your basic rate for each hour of Sunday work which is not overtime (i.e. occasional work on Sunday outside the normal tour of duty is considered overtime work).

** HAZARDOUS PAY DIFFERENTIAL **

An 8 percent differential is applicable to employees employed in a position that represents a high degree of hazard when working with or in close proximity to ordnance, explosives, and incendiary materials.  This includes work such as screening, blending, dying, mixing, and pressing of sensitive ordnance, explosives, and pyrotechnic compositions such as lead azide, black powder and photoflash powder.
 All dry-house activities involving propellants or explosives.  Demilitarization, modification, renovation, demolition, and maintenance operations on sensitive ordnance, explosives and incendiary materials.  All operations involving re-grading and cleaning of artillery ranges.

A 4 percent differential is applicable to employees employed in a position that represents a low degree of hazard when working with, or in close proximity to ordnance, (or employees possibly adjacent to) explosives and incendiary materials which involves potential injury such as laceration of hands, face, or arms of the employee engaged in the operation, irritation of the skin, minor burns and the like; minimal damage to immediate or adjacent work area or equipment being used.  All operations involving, unloading, storage, and hauling of ordnance, explosive, and incendiary ordnance material other than small arms ammunition.  These differentials are only applicable to work that has been specifically designated by the agency for ordnance, explosives, and incendiary material differential pay.

** UNIFORM ALLOWANCE **

If employees are required to wear uniforms in the performance of this contract (either by the terms of the Government contract, by the employer, by the state or local law, etc.), the cost of furnishing such uniforms and maintaining (by laundering or dry cleaning) such uniforms is an expense that may not be borne by an employee where such cost reduces the hourly rate below that required by the wage determination. The Department of Labor will accept payment in accordance with the following standards as compliance:

The contractor or subcontractor is required to furnish all employees with an
adequate number of uniforms without cost or to reimburse employees for the actual cost of the uniforms.  In addition, where uniform cleaning and maintenance is made the responsibility of the employee, all contractors and subcontractors subject to this wage determination shall (in the absence of a bona fide collective bargaining agreement providing for a different amount, or the furnishing of contrary affirmative proof as to the actual cost), reimburse all employees for such cleaning and maintenance at a rate of $3.35 per week (or $.67 cents per day).  However, in those instances where the uniforms furnished are made of "wash and wear" materials, may be routinely washed and dried with other personal garments, and do not require any special treatment such as dry cleaning, daily washing, or commercial laundering in order to meet the cleanliness or appearance standards set by the terms of the Government contract, by the contractor, by law, or by the nature of the work,
there is no requirement that employees be reimbursed for uniform maintenance costs.

** SERVICE CONTRACT ACT DIRECTORY OF OCCUPATIONS **

The duties of employees under job titles listed are those described in the
"Service Contract Act Directory of Occupations", Fifth Edition (Revision 1),
dated September 2015, unless otherwise indicated.

** REQUEST FOR AUTHORIZATION OF ADDITIONAL CLASSIFICATION AND WAGE RATE, Standard
Form 1444 (SF-1444) **

Conformance Process:

The contracting officer shall require that any class of service employee which is not listed herein and which is to be employed under the contract (i.e., the work to be performed is not performed by any classification listed in the wage determination), be classified by the contractor so as to provide a reasonable relationship (i.e., appropriate level of skill comparison) between such unlisted classifications and the classifications listed in the wage determination (See 29 CFR 4.6(b)(2)(i)).  Such conforming procedures shall be initiated by the contractor prior to the performance of contract work by such unlisted class(es) of employees (See 29 CFR 4.6(b)(2)(ii)).  The Wage and Hour Division shall make a final determination of conformed classification, wage rate, and/or fringe benefits which shall be paid to all employees performing in the classification from the first day
of work on which contract work is performed by them in the classification.  Failure to pay such unlisted employees the compensation agreed upon by the interested parties and/or fully determined by the Wage and Hour Division retroactive to the date such class of employees commenced contract work shall be a violation of the Act and this contract.  (See 29 CFR 4.6(b)(2)(v)). When multiple wage determinations are included in a contract, a separate SF-1444 should be prepared for each wage determination to which a class(es) is to be conformed.

The process for preparing a conformance request is as follows:

1) When preparing the bid, the contractor identifies the need for a conformed
occupation(s) and computes a proposed rate(s).

2) After contract award, the contractor prepares a written report listing in order the proposed classification title(s), a Federal grade equivalency (FGE) for each proposed classification(s), job description(s), and rationale for proposed wage rate(s), including information regarding the agreement or disagreement of the authorized representative of the employees involved, or where there is no authorized representative, the employees themselves. This report should be submitted to the contracting officer no later than 30 days after such unlisted class(es) of employees performs any contract work.

3) The contracting officer reviews the proposed action and promptly submits a report of the action, together with the agency's recommendations and pertinent information including the position of the contractor and the employees, to the U.S. Department of Labor, Wage and Hour Division, for review (See 29 CFR 4.6(b)(2)(ii)).

4) Within 30 days of receipt, the Wage and Hour Division approves, modifies, or disapproves the action via transmittal to the agency contracting officer, or notifies the contracting officer that additional time will be required to process the request.

5) The contracting officer transmits the Wage and Hour Division's decision to the contractor.

6) Each affected employee shall be furnished by the contractor with a written copy of such determination or it shall be posted as a part of the wage determination (See 29 CFR 4.6(b)(2)(iii)).

Information required by the Regulations must be submitted on SF-1444 or bond paper.

When preparing a conformance request, the "Service Contract Act Directory of
Occupations" should be used to compare job definitions to ensure that duties
requested are not performed by a classification already listed in the wage
determination. Remember, it is not the job title, but the required tasks that
determine whether a class is included in an established wage determination.
Conformances may not be used to artificially split, combine, or subdivide
classifications listed in the wage determination (See 29 CFR 4.152(c)(1)).

WD 15-4771 (Rev.-10) was first posted on www.wdol.gov on 05/07/2019
************************************************************************************
REGISTER OF WAGE DETERMINATIONS UNDER  |        U.S. DEPARTMENT OF LABOR
       THE SERVICE CONTRACT ACT        |  EMPLOYMENT STANDARDS ADMINISTRATION
By direction of the Secretary of Labor |         WAGE AND HOUR DIVISION
                                       |         WASHINGTON D.C.  20210
                                       |
                                       |
                                       |
                                       | Wage Determination No.: 2015-4771
Daniel W. Simms          Division of   |           Revision No.: 10
Director            Wage Determinations|       Date Of Revision: 05/02/2019
_______________________________________|____________________________________________
Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.60 for
calendar year 2019 applies to all contracts subject to the Service Contract
Act for which the contract is awarded (and any solicitation was issued) on or
after January 1, 2015. If this contract is covered by the EO, the contractor
must pay all workers in any classification listed on this wage determination
at least $10.60 per hour (or the applicable wage rate listed on this wage
determination, if it is higher) for all hours spent performing on the contract in calendar year 2019. The EO minimum wage rate will be adjusted annually. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.
____________________________________________________________________________________
State: Ohio

Area: Ohio Counties of Adams, Athens, Gallia, Highland, Jackson, Meigs, Pike,
Ross, Scioto, Vinton
____________________________________________________________________________________
          **Fringe Benefits Required Follow the Occupational Listing**
OCCUPATION CODE - TITLE                                  FOOTNOTE               RATE
01000 - Administrative Support And Clerical Occupations
  01011 - Accounting Clerk I                                  14.29
  01012 - Accounting Clerk II                                 16.05
  01013 - Accounting Clerk III                                17.95
  01020 - Administrative Assistant                            24.51
  01035 - Court Reporter                                      18.49
  01041 - Customer Service Representative I                   11.38
  01042 - Customer Service Representative II                  12.80
  01043 - Customer Service Representative III                 13.97
  01051 - Data Entry Operator I                               12.82
  01052 - Data Entry Operator II                              13.99
  01060 - Dispatcher, Motor Vehicle                           18.76
  01070 - Document Preparation Clerk                          13.80
  01090 - Duplicating Machine Operator                        13.80
  01111 - General Clerk I                                     12.93
  01112 - General Clerk II                                    14.11
  01113 - General Clerk III                                   15.84
  01120 - Housing Referral Assistant                          19.32
  01141 - Messenger Courier                                   11.94
  01191 - Order Clerk I                                       13.92
  01192 - Order Clerk II                                      15.71
  01261 - Personnel Assistant (Employment) I                  15.69
  01262 - Personnel Assistant (Employment) II                 17.56
  01263 - Personnel Assistant (Employment) III                19.57
  01270 - Production Control Clerk                            22.45
  01290 - Rental Clerk                                        10.78
  01300 - Scheduler, Maintenance                              15.49
  01311 - Secretary I                                         15.49
  01312 - Secretary II                                        17.33
  01313 - Secretary III                                       19.32
  01320 - Service Order Dispatcher                            16.68
  01410 - Supply Technician                                   24.51
  01420 - Survey Worker                                       13.53
  01460 - Switchboard Operator/Receptionist                   11.38
  01531 - Travel Clerk I                                      12.86
  01532 - Travel Clerk II                                     13.72
  01533 - Travel Clerk III                                    14.55
  01611 - Word Processor I                                    14.16
  01612 - Word Processor II                                   15.91
  01613 - Word Processor III                                  17.80
05000 - Automotive Service Occupations
  05005 - Automobile Body Repairer, Fiberglass                19.56
  05010 - Automotive  Electrician                             16.60
  05040 - Automotive Glass Installer                          15.87
  05070 - Automotive Worker                                   15.87
  05110 - Mobile Equipment Servicer                           14.42
  05130 - Motor Equipment Metal Mechanic                      17.26
  05160 - Motor Equipment Metal Worker                        15.87
  05190 - Motor Vehicle Mechanic                              16.77
  05220 - Motor Vehicle Mechanic Helper                       14.33
  05250 - Motor Vehicle Upholstery Worker                     15.13
  05280 - Motor Vehicle Wrecker                               15.87
  05310 - Painter, Automotive                                 16.60
  05340 - Radiator Repair Specialist                          15.87
  05370 - Tire Repairer                                       13.87
  05400 - Transmission Repair Specialist                      17.26
07000 - Food Preparation And Service Occupations
  07010 - Baker                                               16.06
  07041 - Cook I                                              14.66
  07042 - Cook II                                             16.06
  07070 - Dishwasher                                          11.31
  07130 - Food Service Worker                                 11.31
  07210 - Meat Cutter                                         16.06
  07260 - Waiter/Waitress                                     12.28
09000 - Furniture Maintenance And Repair Occupations
  09010 - Electrostatic Spray Painter                         22.00
  09040 - Furniture Handler                                   14.52
  09080 - Furniture Refinisher                                22.00
  09090 - Furniture Refinisher Helper                         17.02
  09110 - Furniture Repairer, Minor                           19.72
  09130 - Upholsterer                                         22.00
11000 - General Services And Support Occupations
  11030 - Cleaner, Vehicles                                   14.87
  11060 - Elevator Operator                                   14.30
  11090 - Gardener                                            14.66
  11122 - Housekeeping Aide                                   14.30
  11150 - Janitor                                             14.30
  11210 - Laborer, Grounds Maintenance                        12.28
  11240 - Maid or Houseman                                    10.04
  11260 - Pruner                                              11.22
  11270 - Tractor Operator                                    13.88
  11330 - Trail Maintenance Worker                            12.28
  11360 - Window Cleaner                                      15.74
12000 - Health Occupations
  12010 - Ambulance Driver                                    13.65
  12011 - Breath Alcohol Technician                           18.39
  12012 - Certified Occupational Therapist Assistant          28.48
  12015 - Certified Physical Therapist Assistant              28.11
  12020 - Dental Assistant                                    17.20
  12025 - Dental Hygienist                                    30.41
  12030 - EKG Technician                                      25.69
  12035 - Electroneurodiagnostic Technologist                 25.69
  12040 - Emergency Medical Technician                        13.65
  12071 - Licensed Practical Nurse I                          16.44
  12072 - Licensed Practical Nurse II                         18.39
  12073 - Licensed Practical Nurse III                        20.50
  12100 - Medical Assistant                                   14.05
  12130 - Medical Laboratory Technician                       23.61
  12160 - Medical Record Clerk                                14.36
  12190 - Medical Record Technician                           16.06
  12195 - Medical Transcriptionist                            16.45
  12210 - Nuclear Medicine Technologist                       32.00
  12221 - Nursing Assistant I                                 12.16
  12222 - Nursing Assistant II                                13.68
  12223 - Nursing Assistant III                               14.93
  12224 - Nursing Assistant IV                                16.76
  12235 - Optical Dispenser                                   18.43
  12236 - Optical Technician                                  16.44
  12250 - Pharmacy Technician                                 13.63
  12280 - Phlebotomist                                        13.59
  12305 - Radiologic Technologist                             25.82
  12311 - Registered Nurse I                                  23.69
  12312 - Registered Nurse II                                 28.98
  12313 - Registered Nurse II, Specialist                     28.98
  12314 - Registered Nurse III                                35.06
  12315 - Registered Nurse III, Anesthetist                   35.06
  12316 - Registered Nurse IV                                 42.02
  12317 - Scheduler (Drug and Alcohol Testing)                22.78
  12320 - Substance Abuse Treatment Counselor                 19.42
13000 - Information And Arts Occupations
  13011 - Exhibits Specialist I                               21.15
  13012 - Exhibits Specialist II                              26.20
  13013 - Exhibits Specialist III                             32.05
  13041 - Illustrator I                                       21.15
  13042 - Illustrator II                                      26.20
  13043 - Illustrator III                                     32.05
  13047 - Librarian                                           29.01
  13050 - Library Aide/Clerk                                  13.98
  13054 - Library Information Technology Systems              26.20
  Administrator
  13058 - Library Technician                                  15.90
  13061 - Media Specialist I                                  18.91
  13062 - Media Specialist II                                 21.15
  13063 - Media Specialist III                                23.57
  13071 - Photographer I                                      18.38
  13072 - Photographer II                                     20.57
  13073 - Photographer III                                    25.48
  13074 - Photographer IV                                     31.00
  13075 - Photographer V                                      37.51
  13090 - Technical Order Library Clerk                       18.26
  13110 - Video Teleconference Technician                     18.91
14000 - Information Technology Occupations
  14041 - Computer Operator I                                 14.61
  14042 - Computer Operator II                                18.72
  14043 - Computer Operator III                               21.15
  14044 - Computer Operator IV                                22.66
  14045 - Computer Operator V                                 25.09
  14071 - Computer Programmer I                          (see 1)               21.74
  14072 - Computer Programmer II                         (see 1)               24.22
  14073 - Computer Programmer III                        (see 1)
  14074 - Computer Programmer IV                         (see 1)
  14101 - Computer Systems Analyst I                     (see 1)
  14102 - Computer Systems Analyst II                    (see 1)
  14103 - Computer Systems Analyst III                   (see 1)
  14150 - Peripheral Equipment Operator                        14.61
  14160 - Personal Computer Support Technician                 22.66
  14170 - System Support Specialist                            26.37
15000 - Instructional Occupations
  15010 - Aircrew Training Devices Instructor (Non-Rated)      28.90
  15020 - Aircrew Training Devices Instructor (Rated)          34.97
  15030 - Air Crew Training Devices Instructor (Pilot)         41.92
  15050 - Computer Based Training Specialist / Instructor      28.90
  15060 - Educational Technologist                             33.25
  15070 - Flight Instructor (Pilot)                            41.92
  15080 - Graphic Artist                                       19.34
  15085 - Maintenance Test Pilot, Fixed, Jet/Prop              41.92
  15086 - Maintenance Test Pilot, Rotary Wing                  41.92
  15088 - Non-Maintenance Test/Co-Pilot                        41.92
  15090 - Technical Instructor                                 21.77
  15095 - Technical Instructor/Course Developer                26.63
  15110 - Test Proctor                                         17.57
  15120 - Tutor                                                17.57
16000 - Laundry, Dry-Cleaning, Pressing And Related Occupations
  16010 - Assembler                                            10.07
  16030 - Counter Attendant                                    10.07
  16040 - Dry Cleaner                                          12.51
  16070 - Finisher, Flatwork, Machine                          10.07
  16090 - Presser, Hand                                        10.07
  16110 - Presser, Machine, Drycleaning                        10.07
  16130 - Presser, Machine, Shirts                             10.07
  16160 - Presser, Machine, Wearing Apparel, Laundry           10.07
  16190 - Sewing Machine Operator                              13.38
  16220 - Tailor                                               14.26
  16250 - Washer, Machine                                      10.71
19000 - Machine Tool Operation And Repair Occupations
  19010 - Machine-Tool Operator (Tool Room)                     17.98
  19040 - Tool And Die Maker                                    21.26
21000 - Materials Handling And Packing Occupations
  21020 - Forklift Operator                                     16.57
  21030 - Material Coordinator                                  22.45
  21040 - Material Expediter                                    22.45
  21050 - Material Handling Laborer                             12.37
  21071 - Order Filler                                          12.45
  21080 - Production Line Worker (Food Processing)              16.57
  21110 - Shipping Packer                                       15.91
  21130 - Shipping/Receiving Clerk                              15.91
  21140 - Store Worker I                                        13.71
  21150 - Stock Clerk                                           18.29
  21210 - Tools And Parts Attendant                             16.57
  21410 - Warehouse Specialist                                  16.57
23000 - Mechanics And Maintenance And Repair Occupations
  23010 - Aerospace Structural Welder                           23.52
  23019 - Aircraft Logs and Records Technician                  19.22
  23021 - Aircraft Mechanic I                                   22.55
  23022 - Aircraft Mechanic II                                  23.52
  23023 - Aircraft Mechanic III                                 24.44
  23040 - Aircraft Mechanic Helper                              16.68
  23050 - Aircraft, Painter                                     21.60
  23060 - Aircraft Servicer                                     19.22
  23070 - Aircraft Survival Flight Equipment Technician         21.60
  23080 - Aircraft Worker                                       20.46
  23091 - Aircrew Life Support Equipment (ALSE) Mechanic        20.46  I
  23092 - Aircrew Life Support Equipment (ALSE) Mechanic        22.55  II
  23110 - Appliance Mechanic                                    22.17
  23120 - Bicycle Repairer                                      18.47
  23125 - Cable Splicer                                         35.17
  23130 - Carpenter, Maintenance                                20.80
  23140 - Carpet Layer                                          22.19
  23160 - Electrician, Maintenance                              32.75
  23181 - Electronics Technician Maintenance I                  25.55
  23182 - Electronics Technician Maintenance II                 28.15
  23183 - Electronics Technician Maintenance III                29.39
  23260 - Fabric Worker                                         20.16
  23290 - Fire Alarm System Mechanic                            23.20
  23310 - Fire Extinguisher Repairer                            18.87
  23311 - Fuel Distribution System Mechanic                     28.75
  23312 - Fuel Distribution System Operator                     23.10
  23370 - General Maintenance Worker                            18.77
  23380 - Ground Support Equipment Mechanic                     22.55
  23381 - Ground Support Equipment Servicer                     19.22
  23382 - Ground Support Equipment Worker                       20.46
  23391 - Gunsmith I                                            18.87
  23392 - Gunsmith II                                           21.52
  23393 - Gunsmith III                                          23.96
  23410 - Heating, Ventilation And Air-Conditioning             19.85
  Mechanic
  23411 - Heating, Ventilation And Air Conditioning             20.73
  Mechanic (Research Facility)
  23430 - Heavy Equipment Mechanic                              22.94
  23440 - Heavy Equipment Operator                              24.12
  23460 - Instrument Mechanic                                 24.45
  23465 - Laboratory/Shelter Mechanic                         22.89
  23470 - Laborer                                             12.37
  23510 - Locksmith                                           22.65
  23530 - Machinery Maintenance Mechanic                      24.40
  23550 - Machinist, Maintenance                              19.47
  23580 - Maintenance Trades Helper                           14.77
  23591 - Metrology Technician I                              24.45
  23592 - Metrology Technician II                             25.50
  23593 - Metrology Technician III                            26.50
  23640 - Millwright                                          24.45
  23710 - Office Appliance Repairer                           22.43
  23760 - Painter, Maintenance                                20.90
  23790 - Pipefitter, Maintenance                             23.67
  23810 - Plumber, Maintenance                                22.67
  23820 - Pneudraulic Systems Mechanic                        23.96
  23850 - Rigger                                              23.96
  23870 - Scale Mechanic                                      21.52
  23890 - Sheet-Metal Worker, Maintenance                     23.87
  23910 - Small Engine Mechanic                               21.01
  23931 - Telecommunications Mechanic I                       26.52
  23932 - Telecommunications Mechanic II                      27.66
  23950 - Telephone Lineman                                   27.50
  23960 - Welder, Combination, Maintenance                    19.07
  23965 - Well Driller                                        23.69
  23970 - Woodcraft Worker                                    23.96
  23980 - Woodworker                                          18.87
24000 - Personal Needs Occupations
  24550 - Case Manager                                        14.70
  24570 - Child Care Attendant                                 9.32
  24580 - Child Care Center Clerk                             11.66
  24610 - Chore Aide                                          10.69
  24620 - Family Readiness And Support Services               14.70
  Coordinator
  24630 - Homemaker                                           14.70
25000 - Plant And System Operations Occupations
  25010 - Boiler Tender                                       30.09
  25040 - Sewage Plant Operator                               20.88
  25070 - Stationary Engineer                                 30.09
  25190 - Ventilation Equipment Tender                        22.23
  25210 - Water Treatment Plant Operator                      20.88
27000 - Protective Service Occupations
  27004 - Alarm Monitor                                       19.40
  27007 - Baggage Inspector                                   14.16
  27008 - Corrections Officer                                 22.58
  27010 - Court Security Officer                              21.76
  27030 - Detection Dog Handler                               15.86
  27040 - Detention Officer                                   22.58
  27070 - Firefighter                                         20.76
  27101 - Guard I                                             14.16
  27102 - Guard II                                            15.86
  27131 - Police Officer I                                    21.11
  27132 - Police Officer II                                   23.46
28000 - Recreation Occupations
  28041 - Carnival Equipment Operator                         14.75
  28042 - Carnival Equipment Repairer                         15.58
  28043 - Carnival Worker                                     12.01
  28210 - Gate Attendant/Gate Tender                          17.79
  28310 - Lifeguard                                           11.90
  28350 - Park Attendant (Aide)                               19.88
  28510 - Recreation Aide/Health Facility Attendant           14.52
  28515 - Recreation Specialist                               24.31
  28630 - Sports Official                                     15.84
  28690 - Swimming Pool Operator                              17.67
29000 - Stevedoring/Longshoremen Occupational Services
  29010 - Blocker And Bracer                                  20.70
  29020 - Hatch Tender                                        20.70
  29030 - Line Handler                                        20.70
  29041 - Stevedore I                                         19.54
  29042 - Stevedore II                                        21.78
30000 - Technical Occupations
  30010 - Air Traffic Control Specialist, Center (HFO)   (see 2)               40.06
  30011 - Air Traffic Control Specialist, Station (HFO)  (see 2)               27.63
  30012 - Air Traffic Control Specialist, Terminal (HFO) (see 2)               30.42
  30021 - Archeological Technician I                           17.53
  30022 - Archeological Technician II                          19.61
  30023 - Archeological Technician III                         24.30
  30030 - Cartographic Technician                              24.30
  30040 - Civil Engineering Technician                         24.16
  30051 - Cryogenic Technician I                               25.69
  30052 - Cryogenic Technician II                              28.38
  30061 - Drafter/CAD Operator I                               17.53
  30062 - Drafter/CAD Operator II                              19.61
  30063 - Drafter/CAD Operator III                             21.86
  30064 - Drafter/CAD Operator IV                              26.90
  30081 - Engineering Technician I                             15.58
  30082 - Engineering Technician II                            18.24
  30083 - Engineering Technician III                           20.23
  30084 - Engineering Technician IV                            25.29
  30085 - Engineering Technician V                             30.93
  30086 - Engineering Technician VI                            37.42
  30090 - Environmental Technician                             23.88
  30095 - Evidence Control Specialist                          23.20
  30210 - Laboratory Technician                                28.20
  30221 - Latent Fingerprint Technician I                      25.69
  30222 - Latent Fingerprint Technician II                     28.38
  30240 - Mathematical Technician                              24.30
  30361 - Paralegal/Legal Assistant I                          20.15
  30362 - Paralegal/Legal Assistant II                         24.96
  30363 - Paralegal/Legal Assistant III                        30.53
  30364 - Paralegal/Legal Assistant IV                         36.94
  30375 - Petroleum Supply Specialist                          28.38
  30390 - Photo-Optics Technician                              22.89
  30395 - Radiation Control Technician                         28.38
  30461 - Technical Writer I                                   25.25
  30462 - Technical Writer II                                  30.89
  30463 - Technical Writer III                                 37.37
  30491 - Unexploded Ordnance (UXO) Technician I               25.46
  30492 - Unexploded Ordnance (UXO) Technician II              30.80
  30493 - Unexploded Ordnance (UXO) Technician III            36.92
  30494 - Unexploded (UXO) Safety Escort                      25.46
  30495 - Unexploded (UXO) Sweep Personnel                    25.46
  30501 - Weather Forecaster I                                25.69
  30502 - Weather Forecaster II                               31.24
  30620 - Weather Observer, Combined Upper Air Or        (see 2)       21.86
  Surface Programs
  30621 - Weather Observer, Senior                       (see 2)       24.30
31000 - Transportation/Mobile Equipment Operation Occupations
  31010 - Airplane Pilot                                       30.80
  31020 - Bus Aide                                             13.92
  31030 - Bus Driver                                           19.58
  31043 - Driver Courier                                       12.98
  31260 - Parking and Lot Attendant                            11.85
  31290 - Shuttle Bus Driver                                   14.04
  31310 - Taxi Driver                                          10.80
  31361 - Truckdriver, Light                                   14.04
  31362 - Truckdriver, Medium                                  16.62
  31363 - Truckdriver, Heavy                                   17.94
  31364 - Truckdriver, Tractor-Trailer                         17.94
99000 - Miscellaneous Occupations
  99020 - Cabin Safety Specialist                              15.02
  99030 - Cashier                                               9.30
  99050 - Desk Clerk                                           10.14
  99095 - Embalmer                                             27.93
  99130 - Flight Follower                                      25.46
  99251 - Laboratory Animal Caretaker I                        15.97
  99252 - Laboratory Animal Caretaker II                       16.78
  99260 - Marketing Analyst                                    28.20
  99310 - Mortician                                            27.93
  99410 - Pest Controller                                      18.71
  99510 - Photofinishing Worker                                13.38
  99710 - Recycling Laborer                                    16.93
  99711 - Recycling Specialist                                 20.08
  99730 - Refuse Collector                                     15.38
  99810 - Sales Clerk                                          10.32
  99820 - School Crossing Guard                                15.22
  99830 - Survey Party Chief                                   22.18
  99831 - Surveying Aide                                       14.69
  99832 - Surveying Technician                                 20.16
  99840 - Vending Machine Attendant                            16.80
  99841 - Vending Machine Repairer                             19.44
  99842 - Vending Machine Repairer Helper                      16.80

____________________________________________________________________________________
Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal
Contractors, applies to all contracts subject to the Service Contract Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017.  If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year. Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family
to the employee) who is the victim of, domestic violence, sexual assault, or
stalking.  Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

ALL OCCUPATIONS LISTED ABOVE RECEIVE THE FOLLOWING BENEFITS:

HEALTH & WELFARE: $4.48 per hour or $179.20 per week or $776.53 per month

HEALTH & WELFARE EO 13706: $4.18 per hour, or $167.20 per week, or $724.53 per month*

*This rate is to be used only when compensating employees for performance on an SCA-covered contract also covered by EO 13706, Establishing Paid Sick Leave for Federal Contractors.  A contractor may not receive credit toward its SCA obligations for any paid sick leave provided pursuant to EO 13706.

VACATION: 2 weeks paid vacation after 1 year of service with a contractor or
successor; 3 weeks after 5 years, 4 weeks after 15 years, and 5 weeks after 25 years.
  Length of service includes the whole span of continuous service with the present contractor or successor, wherever employed, and with the predecessor contractors in the performance of similar work at the same Federal facility.  (Reg. 29 CFR 4.173)

HOLIDAYS: A minimum of eleven paid holidays per year:  New Year's Day, Martin
Luther King Jr's Birthday, Washington's Birthday, Good Friday, Memorial Day,
Independence Day, Labor Day, Columbus Day, Veterans' Day, Thanksgiving Day, and Christmas Day.  A contractor may substitute for any of the named holidays another day off with pay in accordance with a plan communicated to the employees involved.)(See 29 CFR 4.174)

THE OCCUPATIONS WHICH HAVE NUMBERED FOOTNOTES IN PARENTHESES RECEIVE THE FOLLOWING:

1)  COMPUTER EMPLOYEES:  Under the SCA at section 8(b), this wage determination does not apply to any employee who individually qualifies as a bona fide executive, administrative, or professional employee as defined in 29 C.F.R. Part 541.  Because
most Computer System Analysts and Computer Programmers who are compensated at a rate not less than $27.63 (or on a salary or fee basis at a rate not less than $455 per week) an hour would likely qualify as exempt computer professionals, (29 C.F.R. 541. 400) wage rates may not be listed on this wage determination for all occupations within those job families.  In addition, because this wage determination may not list a wage rate for some or all occupations within those job families if the survey data indicates that the prevailing wage rate for the occupation equals or exceeds $27.63 per hour conformances may be necessary for certain nonexempt employees.  For example, if an individual employee is nonexempt but nevertheless performs duties
within the scope of one of the Computer Systems Analyst or Computer Programmer occupations for which this wage determination does not specify an SCA wage rate, then the wage rate for that employee must be conformed in accordance with the conformance procedures described in the conformance note included on this wage determination.

Additionally, because job titles vary widely and change quickly in the computer industry, job titles are not determinative of the application of the computer professional exemption.  Therefore, the exemption applies only to computer employees who satisfy the compensation requirements and whose primary duty consists of:
    (1) The application of systems analysis techniques and procedures, including consulting with users, to determine hardware, software or system functional specifications;
    (2) The design, development, documentation, analysis, creation, testing or modification of computer systems or programs, including prototypes, based on and related to user or system design specifications;
    (3) The design, documentation, testing, creation or modification of computer programs related to machine operating systems; or
    (4) A combination of the aforementioned duties, the performance of which
requires the same level of skills.  (29 C.F.R. 541.400).

2)  AIR TRAFFIC CONTROLLERS AND WEATHER OBSERVERS - NIGHT PAY & SUNDAY PAY:  If you work at night as part of a regular tour of duty, you will earn a night differential and receive an additional 10% of basic pay for any hours worked between 6pm and 6am.
 If you are a full-time employed (40 hours a week) and Sunday is part of your
regularly scheduled workweek, you are paid at your rate of basic pay plus a Sunday premium of 25% of your basic rate for each hour of Sunday work which is not overtime (i.e. occasional work on Sunday outside the normal tour of duty is considered overtime work).

** HAZARDOUS PAY DIFFERENTIAL **

An 8 percent differential is applicable to employees employed in a position that represents a high degree of hazard when working with or in close proximity to ordnance, explosives, and incendiary materials.  This includes work such as screening, blending, dying, mixing, and pressing of sensitive ordnance, explosives, and pyrotechnic compositions such as lead azide, black powder and photoflash powder.
 All dry-house activities involving propellants or explosives.  Demilitarization, modification, renovation, demolition, and maintenance operations on sensitive ordnance, explosives and incendiary materials.  All operations involving re-grading and cleaning of artillery ranges.

A 4 percent differential is applicable to employees employed in a position that represents a low degree of hazard when working with, or in close proximity to ordnance, (or employees possibly adjacent to) explosives and incendiary materials which involves potential injury such as laceration of hands, face, or arms of the employee engaged in the operation, irritation of the skin, minor burns and the like; minimal damage to immediate or adjacent work area or equipment being used.  All operations involving, unloading, storage, and hauling of ordnance, explosive, and incendiary ordnance material other than small arms ammunition.  These differentials are only applicable to work that has been specifically designated by the agency for ordnance, explosives, and incendiary material differential pay.

** UNIFORM ALLOWANCE **

If employees are required to wear uniforms in the performance of this contract (either by the terms of the Government contract, by the employer, by the state or local law, etc.), the cost of furnishing such uniforms and maintaining (by laundering or dry cleaning) such uniforms is an expense that may not be borne by an employee where such cost reduces the hourly rate below that required by the wage determination. The Department of Labor will accept payment in accordance with the following standards as compliance:

The contractor or subcontractor is required to furnish all employees with an
adequate number of uniforms without cost or to reimburse employees for the actual cost of the uniforms.  In addition, where uniform cleaning and maintenance is made the responsibility of the employee, all contractors and subcontractors subject to this wage determination shall (in the absence of a bona fide collective bargaining agreement providing for a different amount, or the furnishing of contrary affirmative proof as to the actual cost), reimburse all employees for such cleaning and maintenance at a rate of $3.35 per week (or $.67 cents per day).  However, in those instances where the uniforms furnished are made of "wash and wear" materials, may be routinely washed and dried with other personal garments, and do not require any special treatment such as dry cleaning, daily washing, or commercial laundering in order to meet the cleanliness or appearance standards set by the terms of the Government contract, by the contractor, by law, or by the nature of the work,
there is no requirement that employees be reimbursed for uniform maintenance costs.

** SERVICE CONTRACT ACT DIRECTORY OF OCCUPATIONS **

The duties of employees under job titles listed are those described in the
"Service Contract Act Directory of Occupations", Fifth Edition (Revision 1),
dated September 2015, unless otherwise indicated.

** REQUEST FOR AUTHORIZATION OF ADDITIONAL CLASSIFICATION AND WAGE RATE, Standard
Form 1444 (SF-1444) **

Conformance Process:

The contracting officer shall require that any class of service employee which is not listed herein and which is to be employed under the contract (i.e., the work to be performed is not performed by any classification listed in the wage determination), be classified by the contractor so as to provide a reasonable relationship (i.e., appropriate level of skill comparison) between such unlisted classifications and the classifications listed in the wage determination (See 29 CFR 4.6(b)(2)(i)).  Such conforming procedures shall be initiated by the contractor prior to the performance of contract work by such unlisted class(es) of employees (See 29 CFR 4.6(b)(2)(ii)).  The Wage and Hour Division shall make a final determination of conformed classification, wage rate, and/or fringe benefits which shall be paid to all employees performing in the classification from the first day of work on which contract work is performed by them in the classification.  Failure
to pay such unlisted employees the compensation agreed upon by the interested
parties and/or fully determined by the Wage and Hour Division retroactive to the
date such class of employees commenced contract work shall be a violation of the Act and this contract.  (See 29 CFR 4.6(b)(2)(v)). When multiple wage determinations are included in a contract, a separate SF-1444 should be prepared for each wage determination to which a class(es) is to be conformed.

The process for preparing a conformance request is as follows:

1) When preparing the bid, the contractor identifies the need for a conformed
occupation(s) and computes a proposed rate(s).

2) After contract award, the contractor prepares a written report listing in order the proposed classification title(s), a Federal grade equivalency (FGE) for each proposed classification(s), job description(s), and rationale for proposed wage rate(s), including information regarding the agreement or disagreement of the authorized representative of the employees involved, or where there is no authorized representative, the employees themselves. This report should be submitted to the contracting officer no later than 30 days after such unlisted class(es) of employees performs any contract work.

3) The contracting officer reviews the proposed action and promptly submits a report of the action, together with the agency's recommendations and pertinent information including the position of the contractor and the employees, to the U.S. Department of Labor, Wage and Hour Division, for review (See 29 CFR 4.6(b)(2)(ii)).

4) Within 30 days of receipt, the Wage and Hour Division approves, modifies, or disapproves the action via transmittal to the agency contracting officer, or notifies the contracting officer that additional time will be required to process the request.

5) The contracting officer transmits the Wage and Hour Division's decision to the contractor.

6) Each affected employee shall be furnished by the contractor with a written copy of such determination or it shall be posted as a part of the wage determination (See 29 CFR 4.6(b)(2)(iii)).

Information required by the Regulations must be submitted on SF-1444 or bond paper.

When preparing a conformance request, the "Service Contract Act Directory of
Occupations" should be used to compare job definitions to ensure that duties
requested are not performed by a classification already listed in the wage
determination. Remember, it is not the job title, but the required tasks that
determine whether a class is included in an established wage determination.
Conformances may not be used to artificially split, combine, or subdivide
classifications listed in the wage determination (See 29 CFR 4.152(c)(1)).

General Decision Number: TN190076 01/04/2019  TN76

Superseded General Decision Number: TN20180077

State: Tennessee

Construction Type: Building

County: Anderson County in Tennessee.

BUILDING CONSTRUCTION PROJECTS (does not include single family
homes or apartments up to and including 4 stories).

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.60 for calendar year 2019 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.60 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2019.  If this contract is covered by the EO and a 
classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must pay workers in that classification at least the wage rate determined through the conformance process set forth in 29 CFR 5.5(a)(1)(ii) (or the EO minimum wage rate,if it is higher than the conformed wage rate).  The EO minimum wage rate will be adjusted annually.  Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number     Publication Date
          0             01/04/2019

 BOIL0453-003 03/01/2018

                                  Rates          Fringes

BOILERMAKER......................$ 30.07            21.61
----------------------------------------------------------------
 BRTN0005-006 05/01/2018

                                  Rates          Fringes

BRICKLAYER.......................$ 27.03             2.29
----------------------------------------------------------------
 CARP0050-002 05/01/2016

                                  Rates          Fringes

CARPENTER (Includes Scaffold   
Building and Excludes Drywall   
Hanging).........................$ 25.33            11.41
----------------------------------------------------------------
 ELEC0760-006 06/01/2018

                                  Rates          Fringes

ELECTRICIAN (Including   
Electrical Installer (Alarms)....$ 25.12            11.30
----------------------------------------------------------------
 ENGI0917-016 05/01/2017

                                  Rates          Fringes

Power Equipment Operator  
     Backhoe/Trackhoe/Excavator..$ 28.26            10.10
     Bulldozer...................$ 28.26            10.10
     Crane.......................$ 28.26            10.10
     Forklift....................$ 25.97            10.10
     Grader/Blade................$ 25.97            10.10
----------------------------------------------------------------
* IRON0384-005 05/01/2018

                                  Rates          Fringes

IRONWORKER, STRUCTURAL AND   
REINFORCING......................$ 27.77            14.22
----------------------------------------------------------------
 LABO0818-001 05/01/2017

                                  Rates          Fringes

Laborers:  
     GROUP 1.....................$ 19.77             6.53
     GROUP 2.....................$ 20.12             6.53

GROUP 1:   Common or General,  Landscaping   

GROUP 2:  Form Work

----------------------------------------------------------------
 PAIN0437-009 05/01/2015

                                  Rates          Fringes

PAINTER (Including Brush,   
Roller, Spray and Drywall   
Finishing/Taper).................$ 26.43            10.05
----------------------------------------------------------------
 PLAS0078-001 05/01/2015

                                  Rates          Fringes

CEMENT MASON/CONCRETE FINISHER...$ 31.00              .06
----------------------------------------------------------------
 PLUM0102-004 05/01/2018

                                  Rates          Fringes

PIPEFITTER, Includes  HVAC   
Pipe Installation................$ 29.01            13.90
----------------------------------------------------------------
 PLUM0102-009 05/01/2018

                                  Rates          Fringes

PLUMBER (Excluding HVAC Pipe   
Installation)....................$ 29.01            13.90
----------------------------------------------------------------
 SHEE0005-012 05/01/2017

                                  Rates          Fringes

SHEET METAL WORKER (Including   
Metal Building Erector (Metal   
Siding/Wall Panel and HVAC   
Duct Installation (Excluding   
Metal Roof Installation).........$ 28.56            11.99
----------------------------------------------------------------
  SUTN2009-075 09/21/2009

                                  Rates          Fringes

CARPENTER (Drywall Hanging   
Only)............................$ 13.00             0.25
  
HVAC MECHANIC (Installation   
of HVAC Unit Only, Excludes   
Installation of HVAC Pipe and   
Duct)............................$ 12.75             1.49
  
LABORER:  Mason Tender - Brick...$ 12.82             0.00
  
LABORER:  Roof Tearoff...........$  9.75             0.49
  
OPERATOR:  Bobcat/Skid   
Steer/Skid Loader................$ 17.05             0.00
  
OPERATOR:  Mechanic..............$ 18.33             3.67
  
OPERATOR:  Paver  (Asphalt,   
Aggregate, and Concrete).........$ 13.50             0.00
  
OPERATOR:  Roller................$ 13.98             0.00
  
ROOFER:  Built up Roof...........$ 12.74             0.00
  
ROOFER:  Rubber Roof.............$ 16.82             4.77
  
ROOFER:  Single Ply Roof.........$ 16.50             0.32
  
SHEET METAL WORKER (Metal   
Roofs Installation)..............$ 15.64             0.00
  
TILE FINISHER....................$ 10.00             0.74
  
TRUCK DRIVER:  Dump Truck........$ 12.56             0.00
----------------------------------------------------------------

WELDERS - Receive rate prescribed for craft performing
operation to which welding is incidental.

================================================================
 
Note: Executive Order (EO) 13706, Establishing Paid Sick Leave
for Federal Contractors applies to all contracts subject to the
Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017.  If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year. Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking.  Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

----------------------------------------------------------------
 

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular
rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average ate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than "SU" or "UAVG" denotes that the union classification and rate were prevailing for that classification in the survey. Example: PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number,005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the "SU" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification.  As this weighted average rate includes all rates reported in the survey, it may include both union and
non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the  classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010
08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

----------------------------------------------------------------

                   WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can
be:

*  an existing published wage determination
*  a survey underlying a wage determination
*  a Wage and Hour Division letter setting forth a position on
   a wage determination matter
*  a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests
for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)
and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations.  Write to:

            Branch of Construction Wage Determinations
            Wage and Hour Division
            U.S. Department of Labor
            200 Constitution Avenue, N.W.
            Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

            Wage and Hour Administrator
            U.S. Department of Labor
            200 Constitution Avenue, N.W.
            Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board).  Write to:

            Administrative Review Board
            U.S. Department of Labor
            200 Constitution Avenue, N.W.
            Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

================================================================

          END OF GENERAL DECISION

General Decision Number: OH190051 05/03/2019  OH51

Superseded General Decision Number: OH20180072

State: Ohio

Construction Type: Building

County: Pike County in Ohio.

BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories).

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.60 for calendar year 2019 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015.  If this contract is covered by the EO, the contractor
must pay all workers in any classification listed on this wage determination at least $10.60 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2019.  If this contract is covered by the EO and a
classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must pay workers in that classification at least the wage rate determined through the conformance process set forth in 29 CFR 5.5(a)(1)(ii) (or the EO minimum wage rate,if it is higher than the conformed wage rate).  The EO minimum wage rate
will be adjusted annually.  Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number     Publication Date
          0              01/04/2019
          1              01/18/2019
          2              02/15/2019
          3              03/01/2019
          4              05/03/2019

 ASBE0080-001 03/07/2016

                                  Rates          Fringes

ASBESTOS WORKER/HEAT & FROST   
INSULATOR........................$ 31.98            20.99
----------------------------------------------------------------
 BROH0039-001 06/01/2017

                                  Rates          Fringes

BRICKLAYER.......................$ 30.84            14.67
----------------------------------------------------------------
 BROH0055-007 06/01/2017

                                  Rates          Fringes

TILE FINISHER....................$ 26.66             6.00
TILE SETTER......................$ 26.90            13.04
----------------------------------------------------------------
 ELEC0575-004 12/31/2018

                                  Rates          Fringes

ELECTRICIAN (Excludes Low   
Voltage Wiring and   
Installation of Alarms)..........$ 32.75            16.81
----------------------------------------------------------------
 ELEC0972-008 06/01/2017

                                  Rates          Fringes

ELECTRICIAN (Low Voltage   
Wiring and Alarm Installation   
Only)............................$ 32.81            24.54
----------------------------------------------------------------
 ELEV0011-002 01/01/2019

                                  Rates          Fringes

ELEVATOR MECHANIC................$ 45.73       33.705+a+b

PAID HOLIDAYS:

  a. New Year's Day, Memorial Day, Independence Day, Labor Day,
  Veteran's Day, Thanksgiving Day, the Friday after   Thanksgiving, and Christmas Day.

  b. Employer contributes 8% of regular hourly rate to vacation   pay credit for employee who has worked in business more   than 5 years; 6% for less than 5 years' service.

----------------------------------------------------------------
* ENGI0018-022 05/01/2019

                                  Rates          Fringes

POWER EQUIPMENT OPERATOR  
     Bobcat/Skid Steer/Skid 
     Loader; Bulldozer...........$ 37.27            14.86
     Crane.......................$ 37.39            14.86
     Forklift....................$ 36.23            14.86
----------------------------------------------------------------
 IRON0550-012 05/01/2018

                                  Rates          Fringes

IRONWORKER, ORNAMENTAL...........$ 27.60            19.61
----------------------------------------------------------------
 IRON0769-001 06/01/2018

                                  Rates          Fringes

IRONWORKER, STRUCTURAL...........$ 31.67            25.27
----------------------------------------------------------------
 LABO0083-003 06/01/2018

                                  Rates          Fringes

LABORER  
     Common or General; Mason 
     Tender - Brick & 
     Cement/Concrete.............$ 35.41            10.90
----------------------------------------------------------------
 PAIN0093-003 12/01/2018

                                  Rates          Fringes

PAINTER (Brush and Roller).......$ 25.88            18.50
----------------------------------------------------------------
 PAIN1195-001 12/01/2018

                                  Rates          Fringes

GLAZIER..........................$ 31.70            11.12
----------------------------------------------------------------
 PLAS0132-011 06/01/2017

                                  Rates          Fringes

CEMENT MASON/CONCRETE FINISHER...$ 29.94            20.57
----------------------------------------------------------------
 PLUM0577-001 06/01/2018

                                  Rates          Fringes

PIPEFITTER (Excludes HVAC   
Pipe Installation)...............$ 29.75            23.85
----------------------------------------------------------------
 PLUM0577-003 06/01/2018

                                  Rates          Fringes

PLUMBER (Includes HVAC Pipe   
Installation)....................$ 29.75            23.85
----------------------------------------------------------------
 SFOH0669-009 04/01/2017

                                  Rates          Fringes

SPRINKLER FITTER (Fire   
Sprinklers)......................$ 36.33            15.84
----------------------------------------------------------------
 SHEE0024-010 06/01/2017

                                  Rates          Fringes

SHEET METAL WORKER (HVAC Duct   
and Unit Installation Only)......$ 28.32            24.71
----------------------------------------------------------------
 SHEE0033-008 07/01/2017

                                  Rates          Fringes

SHEET METAL WORKER (Excludes   
HVAC Duct and Unit   
Installation)....................$ 30.21            24.82
----------------------------------------------------------------
* UAVG-OH-0001 01/01/2019

                                  Rates          Fringes

IRONWORKER, REINFORCING..........$ 29.44            22.68
----------------------------------------------------------------
* UAVG-OH-0002 01/01/2019

                                  Rates          Fringes

ROOFER...........................$ 30.19            15.73
----------------------------------------------------------------
  SUOH2012-053 08/29/2014

                                  Rates          Fringes

CARPENTER........................$ 25.80            12.54
  
DRYWALL FINISHER/TAPER...........$ 20.66             4.91
  
DRYWALL HANGER AND METAL STUD   
INSTALLER........................$ 22.27            14.40
  
LABORER:  Pipelayer..............$ 18.37             4.79
  
OPERATOR:    
Backhoe/Excavator/Trackhoe.......$ 29.18            10.69
  
OPERATOR:  Loader................$ 22.69             8.01
  
OPERATOR:  Paver  (Asphalt,   
Aggregate, and Concrete).........$ 23.91            10.42
  
TRUCK DRIVER: Dump (All Types)...$ 19.33             6.55
----------------------------------------------------------------

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

================================================================
 
Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017.  If this contract is covered by the EO, the contractor must provide
employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year. Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking.  Additional information on contractor requirements and worker protections under the EO
is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

----------------------------------------------------------------
 

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular
rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than "SU" or "UAVG" denotes that the union classification and rate were prevailing for that classification in the survey. Example: PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1,2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the "SU" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification.  As this weighted average rate includes all rates reported in the survey, it may include both union and
non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier. 
 
Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010
08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

 

----------------------------------------------------------------

                   WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

*  an existing published wage determination
*  a survey underlying a wage determination
*  a Wage and Hour Division letter setting forth a position on
   a wage determination matter
*  a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)
and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations.  Write to:

            Branch of Construction Wage Determinations
            Wage and Hour Division
            U.S. Department of Labor
            200 Constitution Avenue, N.W.
            Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

            Wage and Hour Administrator
            U.S. Department of Labor
            200 Constitution Avenue, N.W.
            Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board).  Write to:

            Administrative Review Board
            U.S. Department of Labor
            200 Constitution Avenue, N.W.
            Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

================================================================

          END OF GENERAL DECISION

    

Eight (8) DOE-owned AC-100 centrifuges currently stored at ACO’s Technology Manufacturing Center in Oak Ridge, TN

Hydrotested and certified 5” cylinders and valves used for the HALEU Cascade Operations

NOTE: Other equipment/material identified in ACO’s definitization proposal to be added.

The following deliverables are required under the Contractor; however, additional reports may be required by specific clauses in the Contract.  

    
	
			
	Report
	Due Date
	Reference

	Monthly Status Report
	10th day of each month
	Section C.5

	Integrated Project Schedule
	30 days after award of letter contract
	Section C.5

	Work Breakdown Structure and Baseline
	30 days after award of letter contract
	Section C.5

	Estimating System Disclosure
	60 days after award of letter contract
	H.3  DOE-H-2023 Cost Estimating System Requirements (Oct 2014)

	Accounting System Disclosure
	60 days after award of letter contract
	H.4  DOE-H-2025 Accounting System Administration (Oct 2014) (Revised)

	Property Management System Disclosure
	60 days after award of letter contract
	H.4  DOE-H-2027 Contractor Property Management System Administration (Oct 2014) (Revised)

	Diversity Program
	30 days after award of the letter contract
	H.9 DOE-H-2046 Diversity Program (Oct 2014)

	Diversity Report
	Annually, on the anniversary of the letter contract award date
	H.9  DOE-H-2046 Diversity Program (Oct 2014)

	Workplace Substance Abuse Program
	Within 30 days of letter contract award
	H.27  DOE-H-2079 Agreement Regarding Workplace Substance Abuse Programs At Doe Sites (Apr 2018) (Revised)

	Indirect and Revised Billing Rates
	Annually, Within 6 months following expiration of Contractor Fiscal Year
	FAR 52.216-7, Allowable Cost and Payment

viExhibit 10.1

 

LEASE

 

DATED

 

August
9, 2019

 

by and
between

 

IIP-PA
4 LLC, 

a Delaware
limited liability company

 

and

 

PHARMACANN PENN PLANT LLC,

a Pennsylvania limited liability company

 

     

     

    

 

LEASE AGREEMENT

 

This Lease Agreement
(this “Lease“), dated August 9, 2019 (the “Execution Date”), is made between IIP-PA 4 LLC,
a Delaware limited liability company (“Landlord“), and PHARMACANN PENN PLANT LLC, a Pennsylvania limited liability
company (“Tenant“).

 

RECITALS

 

A.           
WHEREAS, reference is made to that certain Purchase and Sale Agreement and Joint Escrow Instructions dated August 5, 2019
(the “Purchase Agreement”), pursuant to which Landlord agreed to purchase from Tenant the property located at
Lot No. 4, Scott Technology Park, Scott Township, Pennsylvania, as more particularly described on Exhibit A attached hereto
and incorporated herein by reference (the “Property”);

 

B.            
WHEREAS, concurrent with the execution of this Lease, Landlord acquired the Property pursuant to the Purchase Agreement;

 

C.            
WHEREAS, concurrent with the execution of this Lease, Landlord, Tenant and IIP Operating Partnership, LP entered into a
Development Agreement for the development of certain industrial and greenhouse improvements on the Property (the “Development
Agreement”);

 

D.            
WHEREAS, concurrent with the execution of this Lease, Landlord, Tenant and MedMen Enterprises Inc., a British Columbia corporation
(“MedMen”) entered into a Multi-Party PA Agreement (the “Multi-Party PA Agreement”);

 

E.             
WHEREAS, Landlord wishes to lease to Tenant, and Tenant desires to lease from Landlord, the Premises (as defined below),
pursuant to the terms and conditions of this Lease, as detailed below; and

 

F.             
WHEREAS, each of PharmaCann LLC; PharmaCann of New York, LLC; PharmaCann DC LLC; PharmaCann Florida LLC; Sunbiz Acquisition,
LLC; PharmaCann Virginia LLC; PharmaCann New Jersey LLC; PharmaCannis Labs LLC; PharmaCann Holdings LLC; PC 1200 East Mazon LLC;
PC 16280 East Twombly LLC; PharmaCann Mass LLC; Pharmacannis Massachusetts Inc.; PharmaCann Michigan LLC; 1313 Johnson LLC; PCL
Management LLC; PharmaCann Penn LLC; PharmaCann Ohio LLC; 4104 North Columbus LLC; PC NJ 2 LLC; and Midwest Compassion Center Inc.
(each a “Guarantor”) is an affiliate of Tenant that is deriving a benefit from Landlord and Tenant entering
into this Lease, and has agreed to enter into a guaranty in the form attached as Exhibit D hereto (the “Guaranty”),
without which Landlord would not agree to enter into this Lease.

 

AGREEMENT

 

NOW, THEREFORE, Landlord
and Tenant, in consideration of the mutual promises contained herein and for other good and valuable consideration, the receipt
and sufficiency of which are hereby acknowledged, and intending to be legally bound, agree as follows:

 

1.            
Lease of Premises. Landlord hereby leases to Tenant, and Tenant hereby leases from Landlord, the Property, together
with the following (to the extent now existing or hereafter constructed or installed on the Property) improvements, including shafts,
cable runs, mechanical spaces, rooftop areas, landscaping, parking facilities, private drives and other improvements and appurtenances
related thereto (including any buildings located on the Property), for use by Tenant in accordance with the Permitted Use (as defined
below) and no other uses (collectively, the “Premises”). 

 

2.            
Basic Lease Provisions. For convenience of the parties, certain basic provisions of this Lease are set forth herein.
The provisions set forth herein are subject to the remaining terms and conditions of this Lease and are to be interpreted in light
of such remaining terms and conditions.

 

2.1.          
The monthly Base Rent for the first twelve (12) months of the Term of the Lease shall be equal to Two Hundred Sixty Thousand
Dollars ($260,000.00) subject to subsequent adjustment under this Lease (as may be adjusted, the “Monthly Base Rent
Amount”). 

 

    2

     

    

 

2.2.          
“Security Deposit”: “Security Deposit”:
Seven Hundred Eighty Thousand Dollars ($780,000.00) which shall be funded as follows: (a) Twenty-Eight Thousand Two Hundred Sixty
Dollars ($28,260.00) to be paid upon execution of this Agreement and (b) the remaining portion to be paid by Tenant (using its
own funds) in installments in accordance with this Section 2.2. Within two (2) Business Days following the date that Landlord
makes any Construction Payment (as defined in the Development Agreement) to Tenant, Tenant shall deliver to Landlord a proportionate
amount of the remaining balance of the Security Deposit as determined based upon the percentage derived from dividing (a) the amount
of the Construction Payment by (b) the maximum amount of the Construction Contribution Amount (as defined in the Development Agreement),
until such time as the Security Deposit has been fully funded. As an example, if the maximum Construction Contribution Amount is
$25,058,000, and the amount of the Construction Payment made to Tenant under the Development Agreement is equal to $5,011,600 (i.e.
20% of $26,000,000), then Tenant shall be required to pay an amount equal to $150,348 (i.e. $780,000 - $28,260 = $751,740 x
20% = $150,348) within such two (2) Business Day time period, which amount shall be retained by Landlord as part of the Security
Deposit. Notwithstanding the foregoing (and regardless of the amount of Construction Payments then requested to be funded by Tenant),
the full Security Deposit shall be funded by Tenant no later than the date that is eighteen (18) months following the Execution
Date.

 

2.3.          
“Permitted Use”: Agricultural growth, propagation, processing and dispensing
of agricultural materials (including cannabis), industrial and office space, in accordance with current zoning for the Premises
and in conformity with all Applicable Laws (as defined below). Permitted Use shall include the cultivation, propagation and processing
of cannabis plant parts and resins into products, the storage of same for transport, operation of a registered cannabis dispensary,
and such other related use or uses permitted under Applicable Laws. As used herein, the term “License”
shall mean and refer to that certain license issued by the applicable governmental agency with jurisdiction over the Permitted
Use under which Tenant is authorized to engage in the agricultural growth, propagation, processing and/or dispensing of cannabis
for medical-use purposes. 

 

	2.4.          Address for Rent Payment:	 	 
	 	 	 
	 	 	 
	 	 	 
	 	 	 
	 	 	 
	 	 	 
	2.5.          Address for Notices to Landlord:	IIP-PA 4 LLC	 
	 	11440 West Bernardo Court, Suite 220	 
	 	San Diego, California 92127	 
	 	Attn: General Counsel	 
	 	 	 
	2.6.          Address for Notices and Invoices to Tenant:	 
	 	 
	 	PharmaCann Penn Plant LLC	 
	 	c/o PharmaCann LLC	 
	 	190 South LaSalle Street, Suite 2950	 
	 	Chicago, IL 60603	 
	 	Attn: Accounts Payable	 

 

	 
	2.7.          The following Exhibits are attached hereto and incorporated herein by reference:
	 
	Exhibit A	Property
	Exhibit B	Tenant’s Personal Property
	Exhibit C	Form of Estoppel Certificate
	Exhibit D	Form of Guaranty
	Exhibit E	Tenant Work Insurance Requirements

 

2.8.           
As used herein, “Prior Course of Dealing” shall mean the prior practice
or course of dealing on the projects undertaken by and between affiliates of Landlord and Tenant which are located at 465 Hopping
Brook Road, Holliston, Massachusetts and 10767 Mill Dam Road, Buckeye Lake Village, Ohio. 

 

    3

     

    

 

3.             
Term and Extension Options. 

 

3.1.          
Term. The actual term of this Lease (as the same may be extended or earlier terminated in accordance with this Lease,
the “Term”) shall commence on the Execution Date (also referred to herein
as the “Commencement Date”) and end on November 8, 2034, subject to extension
or earlier termination of this Lease as provided herein.

 

3.2.          
Options to Extend Term. Tenant shall have two (2) options (each an “Extension Option“)
to extend the Term of this Lease for a period of five (5) years each (each an “Extension Period“),
on the same terms and conditions in effect under this Lease immediately prior to the commencement of the Extension Period, except
that (a) Tenant shall have no further right to extend the Term of this Lease after the second Extension Period, (b) the
Base Rent payable during the Extension Period shall be an amount equal to Base Rent in effect immediately prior to the Extension
Period, increased by two and one-half percent (2.5%) on an annual basis. If Tenant exercises an Extension Option, such Extension
Option shall apply to the entire Premises (and no less than the entire Premises). Tenant may exercise an Extension Option only
by giving Landlord irrevocable and unconditional written notice thereof (the “Extension Notice“)
not later than twelve (12) months prior to the commencement date of the Extension Period. Upon delivery of the Extension Notice,
Tenant shall be irrevocably bound to lease the Premises for the Extension Period. Notwithstanding the foregoing, Tenant shall not
have the right to exercise an Extension Option (a) during the time commencing from the date Landlord delivers to Tenant a written
notice that Tenant is in default under any provisions of this Lease and continuing until Tenant has cured the specified default;
(b) at any time after any Default (provided, however, that, for purposes of this Section 3.2, Landlord shall not be required
to provide Tenant with notice of such Default) and continuing until Tenant cures any such Default, if such Default is susceptible
to being cured; or (c) in the event that Tenant has defaulted in the performance of its obligations under this Lease two (2) or
more times during the twelve (12)-month period immediately prior to the date that Tenant intends to exercise an Extension Option,
and such defaults were not cured within the applicable cure period. If Tenant shall fail to timely exercise the Extension Option
in accordance with the provisions of this Section 3.2, then the Extension Option shall terminate, and shall be null and
void and of no further force and effect. If this Lease or Tenant’s right to possession of the Premises shall terminate in
any manner whatsoever before Tenant shall exercise the Extension Option, or if Tenant shall have assigned or transferred any interest
in this Lease or sublet any part of the Premises (except pursuant to a Permitted Transfer, as defined below), then immediately
upon such termination, assignment, transfer or sublease, the Extension Option shall simultaneously terminate and become null and
void. Time is of the essence with regard to this Section 3.2. 

 

3.3.          
The Extension Options are conditioned upon each Guarantor executing an amendment to such Guarantor’s Guaranty that
explicitly extends such Guarantor’s obligations so that each Guarantor guarantees Tenant’s Lease obligations incurred
pursuant to Tenant’s successful exercise of an Extension Option. 

 

4.             
Possession.

 

4.1.          
Possession. Tenant hereby acknowledges that it is familiar with the condition thereof and accepts the Premises in
its “as is” condition with all faults, and Landlord makes no representation or warranty of any kind with respect the
Premises, and Landlord will have no obligation to improve, alter or repair the Premises. It is understood and agreed that Landlord
is not obligated to install any equipment, or make any repairs, improvements or alterations to the Premises. Tenant’s continued
occupancy and possession of the Premises following the Closing (as defined in the Purchase Agreement) shall conclusively establish
that the Premises, any improvements located on the Property and the Project were at such time in good, sanitary and satisfactory
condition and repair. From and after the Commencement Date, Tenant may access and occupy portions of the Property in preparation
of the Permitted Use. 

 

4.2.          
NOTWITHSTANDING ANYTHING TO THE CONTRARY HEREIN, IT IS EXPRESSLY UNDERSTOOD AND AGREED
THAT LANDLORD IS LEASING THE PREMISES “AS IS” AND “WHERE IS,” AND WITH ALL FAULTS, AND THAT LANDLORD IS
MAKING NO REPRESENTATIONS AND WARRANTIES WHETHER EXPRESS OR IMPLIED, BY OPERATION OF LAW OR OTHERWISE, WITH RESPECT TO THE QUALITY
OR PHYSICAL CONDITION OF THE PREMISES, THE INCOME OR EXPENSES FROM OR OF THE PREMISES, OR THE COMPLIANCE OF THE PREMISES WITH APPLICABLE
BUILDING OR FIRE CODES, ENVIRONMENTAL LAWS OR OTHER LAWS, RULES, ORDERS OR REGULATIONS. WITHOUT LIMITING THE FOREGOING, IT IS UNDERSTOOD
AND AGREED THAT LANDLORD MAKES NO WARRANTY WITH RESPECT TO THE HABITABILITY, SUITABILITY, MERCHANTABILITY OR FITNESS FOR A PARTICULAR
PURPOSE. TENANT AGREES THAT IT ASSUMES FULL RESPONSIBILITY FOR, AND THAT IT HAS PERFORMED EXAMINATIONS AND INVESTIGATIONS OF THE
PREMISES, INCLUDING SPECIFICALLY, WITHOUT LIMITATION, EXAMINATIONS AND INVESTIGATIONS FOR THE PRESENCE OF ASBESTOS, PCBS AND OTHER
HAZARDOUS SUBSTANCES, MATERIALS AND WASTES (AS THOSE TERMS MAY BE DEFINED HEREIN OR BY APPLICABLE FEDERAL OR STATE LAWS, RULES
OR REGULATIONS) ON OR IN THE PREMISES. WITHOUT LIMITING THE FOREGOING, TENANT IRREVOCABLY WAIVES ALL CLAIMS AGAINST LANDLORD WITH
RESPECT TO ANY ENVIRONMENTAL CONDITION, INCLUDING CONTRIBUTION AND INDEMNITY CLAIMS, WHETHER STATUTORY OR OTHERWISE. TENANT ASSUMES
FULL RESPONSIBILITY FOR ALL COSTS AND EXPENSES REQUIRED TO CAUSE THE PREMISES TO COMPLY WITH ALL APPLICABLE BUILDING AND FIRE CODES,
MUNICIPAL ORDINANCES, ENVIRONMENTAL LAWS AND OTHER LAWS, RULES, ORDERS, AND REGULATIONS.

 

    4

     

    

 

4.3.          
Holding Over.

 

4.3.1.        
If, with Landlord’s prior written consent, Tenant holds possession of all or any part of the Premises after the Term,
Tenant shall become a tenant from month-to-month after the expiration or earlier termination of the Term, and in such case Tenant
shall continue to pay (a) Base Rent, as adjusted in accordance with Section 5.2, (b) Additional Rent, and (c) any amounts
for which Tenant would otherwise be liable under this Lease if the Lease were still in effect. Any such month-to-month tenancy
shall be subject to every other term, covenant and agreement contained herein.

 

4.3.2.        
If Tenant retains possession of any portion of the Premises after the Term without Landlord’s prior written consent,
then (a) Tenant shall be a tenant at sufferance subject to the terms and conditions of this Lease, except that the monthly rent
shall be equal to one hundred fifty percent (150%) of the monthly Rent in effect during the last thirty (30) days of the Term,
and (b) Tenant shall be liable to Landlord for any and all damages suffered by Landlord as a result of such holdover, including
any lost rent or consequential, special and indirect damages (in each case, regardless of whether such damages are foreseeable).

 

4.3.3.        
Acceptance by Landlord of Rent after the expiration or earlier termination of the Term shall not result in an extension,
renewal or reinstatement of this Lease. The foregoing provisions of this Section 4.3 are in addition to and do not affect
Landlord’s right of reentry or any other rights of Landlord hereunder or as otherwise provided by Applicable Laws. The provisions
of this Section 4.3 shall survive the expiration or earlier termination of this Lease.

 

5.            
Rent.

 

5.1.           
Rent. Base Rent and Additional Rent (defined below) shall together be denominated “Rent.”
Rent shall be paid by ACH, wire transfer or check (but in no event may Rent be payable in cash) to Landlord, without abatement,
deduction or offset (except as expressly provided in this Lease), in lawful money of the United States of America to the address
set forth in Section 2.4 or to such other person or at such other place as Landlord may from time designate in writing.
In the event the Term commences on a day other than the first day of a calendar month or ends on a day other than the last day
of a calendar month, then the Rent for such fraction of a month shall be prorated for such period on the basis of the number of
days in the month and shall be paid at the then-current rate for such fractional month. 

 

5.2.          
Base Rent.

 

5.2.1.        
Initial Base Rent. Tenant shall pay to Landlord as initial Base Rent for the Premises, commencing upon the Commencement
Date, an amount equal to the Monthly Base Rent Amount in equal monthly installments, subject to the rental adjustments provided
in this Section 5.2 (“Base Rent”), each in advance on, or before,
the first day of each and every calendar month during the Term; provided that Base Rent shall be abated until November 9, 2019
(the “Base Rent Abatement Period”). In the event that the Commencement
Date occurs on a day other than the first day of a calendar month, then monthly Base Rent payable on or before the first day of
the first month of the Base Rent Abatement Period shall be a prorated amount based on the actual number of days in such calendar
month, based on a 360 day year, following the expiration of the Base Rent Abatement Period. For purposes of clarity, Tenant shall
be responsible for all other Rent due pursuant to the terms of this Lease during the Base Rent Abatement Period. 

 

    5

     

    

 

5.2.2.        
Annual Escalation. Base Rent payable under this Lease shall be subject to an annual upward adjustment of two and
one-half percent (2.5%) of the then-current Base Rent. The first such adjustment shall become effective commencing on the first
annual anniversary of the Commencement Date, and subsequent adjustments shall become effective on every successive annual anniversary
of the Commencement Date during the Term. 

 

5.2.3.        
Base Rent Adjustment. Notwithstanding the foregoing, in the event that (i) there is a Disbursement Claim (as defined
in the Development Agreement) that is submitted to arbitration pursuant to Section 11 of the Development Agreement, (ii)
the Final Arbitration Decision (as defined in the Development Agreement) mandates that Landlord pay any Required Arbitration Construction
Payments (as defined in the Development Agreement) to Tenant, and (iii) Tenant provides Landlord with written notice and reasonable
supporting evidence that Tenant funded such Required Arbitration Construction Payments (the date of such funding, is referred
to herein as the “Funding Date”), then, in addition to the remedies
available to Tenant hereunder and in the Development Agreement, Base Rent shall be adjusted as follows: 

 

		(a)	the Monthly Base Rent Amount shall be reduced by the quotient of: (x) the product of 12% multiplied
by the Required Arbitration Construction Payments actually funded by Tenant, which is then (y) divided by twelve (12); and from
and after the Funding Date, Tenant shall pay such adjusted Monthly Base Rent Amount (as such amount may be further adjusted pursuant
to Subsection 5.2.3(b), below), subject to the provisions of Section 5.2.2 [for example, if Tenant funds Required
Arbitration Construction Payments equal to $100,000, then the Monthly Base Rent Amount shall be reduced by $1,000 ($100,000 x .12
= $12,000 ÷ 12 = $1,000)]; and

 

		(b)	in addition, Tenant shall receive a one-time credit against Rent payable hereunder equal to the
product of (i) the total reduction in Monthly Base Rent Amount calculated in paragraph (a), above, multiplied by (ii) the number
of monthly Base Rent payments actually paid by Tenant prior to the Funding Date [if Tenant funds the payments in the prior example
after paying 5 Base Rent installments at the original Monthly Base Rent Amount, then the one-time credit would equal $5,000 ($1,000
x 5)] (if necessary, the one-time credit may be applied to more than one installment of Rent until the credit has been fully
applied).

 

In the event that,
following any adjustment to Base Rent as provided in Subsection 5.2.3(a) above, Landlord reimburses Tenant in full for the
Required Arbitration Construction Payments previously funded by Tenant (the date of such reimbursement is referred to herein as
the “Reimbursement Date”), then from and after the Reimbursement Date, the Monthly Base Rent Amount required
to be paid by Tenant shall revert to the original Monthly Base Rent Amount as provided in Section 2.1 without adjustment
pursuant to Subsection 5.2.3(a) (but subject to any unapplied credit due to Tenant pursuant to Subsection 5.2.3(b)
above), and Tenant shall have no obligation to repay or return to Landlord the portion of the original Monthly Base Rent Amount
that Tenant was not required to pay based upon the reduction to the Monthly Base Rent Amount that was calculated pursuant to Section
5.2.3(a) above for the time period between the Funding Date and the Reimbursement Date.

 

5.3.          
Additional Rent. In addition to Base Rent, Tenant shall pay to Landlord as additional rent (“Additional
Rent”) at times hereinafter specified in this Lease (a) amounts related to Operating Expenses
and Taxes (each as defined below), unless paid directly by Tenant to third parties to whom such amounts are owed, and (b) the Property
Management Fee (as defined below) and (c) any other amounts that Tenant assumes or agrees to pay under the provisions of this Lease
that are owed to Landlord (whether or not such amounts are referred to herein as Additional Rent), including any and all other
sums that may become due by reason of any default of Tenant or failure on Tenant’s part to comply with the agreements, terms,
covenants and conditions of this Lease to be performed by Tenant.

 

    6

     

    

 

5.3.1.        
Operating Expenses. Tenant will pay directly all Operating Expenses of the Premises in a timely manner and prior
to delinquency, unless otherwise specified herein that Landlord shall pay directly such Operating Expenses and receive reimbursement
from Tenant. In the event that Tenant fails to pay any Operating Expense within fifteen (15) days after written notice by Landlord
to Tenant, and without being under any obligation to do so and without hereby waiving any default by Tenant, Landlord may pay
any delinquent Operating Expenses. Any Operating Expense paid by Landlord and any expenses reasonably incurred by Landlord in
connection with the payment of the delinquent Operating Expense may be billed immediately to Tenant, or at Landlord’s option
and upon written notice to Tenant, may be deducted from the Security Deposit. “Operating Expenses”
means all costs and expenses incurred by Landlord with respect to the ownership, maintenance and operation of the Premises including,
but not limited to: insurance, maintenance, repair and replacement of the foundation, roof, walls, heating, ventilation,
air conditioning, plumbing, electrical, mechanical, utility and safety systems, paving and parking areas, roads and driveways;
maintenance of exterior areas such as gardening and landscaping, snow removal and signage; maintenance and repair of roof membrane,
flashings, gutters, downspouts, roof drains, skylights and waterproofing; painting; lighting; cleaning; refuse removal; security;
utilities for, or the maintenance of, outside areas; building personnel costs; personal property taxes; rentals or lease payments
paid by Landlord for rented or leased personal property used in the operation or maintenance of the Premises; and fees for required
licenses and permits. Notwithstanding the foregoing, Landlord may not engage in any activity (including paying any expenses) to
the extent such activity is prohibited by Applicable Law or that could reasonably be expected to endanger Tenant’s maintenance
of the License. 

 

5.3.2.        
Taxes. Tenant will promptly pay to Landlord upon Landlord’s written request the amount of all Taxes levied
and assessed for any such year upon the Premises. “Taxes” means any
and all real estate taxes, fees, assessments and other charges of any kind or nature, whether general, special, ordinary or extraordinary,
that Landlord shall pay or accrue (without regard to any different fiscal year used by such governmental authority) that are levied
in respect of the Premises, or in respect of any improvement, fixture, equipment or other property of Landlord, real or personal,
located at the Premises, or used in connection with the operation of the Premises, and all fees, expenses, and costs incurred
by Landlord in investigating, protesting, contesting, or in any way seeking to reduce or avoid increases in any assessments, levies,
or the tax rate pertaining to the Taxes. Taxes shall not include Landlord’s corporate franchise taxes, estate taxes, inheritance
taxes or federal or state income taxes. Tenant shall have the right to protest Taxes, and, if successful, may deduct the reasonable
costs of such protest from Rent, and Landlord shall cooperate (at no cost to Landlord) with any efforts by Tenant in connection
therewith.

 

5.3.3.        
Estimated Costs. If and to the extent applicable, within sixty (60) days
after the Commencement Date, and within sixty (60) days after the beginning of each calendar year, Landlord shall give Tenant
a written estimate, for such calendar year, of the cost of Taxes and Operating Expenses payable by Landlord. Tenant shall pay
such estimated amount to Landlord in equal monthly installments, in advance. Within
ninety (90) days after the end of each calendar year, Landlord shall furnish to Tenant a statement showing in reasonable
detail the cost of Taxes and Operating Expenses paid or payable by Landlord, and any other costs incurred by Landlord for the
operation and maintenance of the Premises during such year (the “Annual
Statement”), and Tenant shall pay to Landlord the cost incurred by Landlord in excess
of the payments made by Tenant within ten (10) days of receipt of such Annual Statement. In the event that the payments made
by Tenant to Landlord for the estimated Taxes and Operating Expenses exceed the aggregate amount set forth in the Annual Statement,
such excess amount shall be credited by Landlord to the Rent or other charges next due and owing, provided that, if the Term has
expired, Landlord shall promptly pay such amount to Tenant along with delivery of the Annual Statement. 

 

5.3.4.        
Property Management Fee. Tenant shall pay to Landlord on, or before, the first day of each calendar month of the
Term, as Additional Rent, the Property Management Fee. The "Property Management Fee"
shall equal one and one-half percent (1.5%) of the then-current Base Rent due from
Tenant. Tenant shall pay the Property Management Fee with respect to the entire Term, including any extensions thereof or any
holdover periods, regardless of whether Tenant is obligated to pay Base Rent or any other Rent with respect to any such period
or portion thereof.

 

5.3.5.        
Absolute Net Lease. This Lease shall be deemed and construed to be an “absolute net lease” and, except
as herein expressly provided, the Landlord shall receive all payments required to be made by Tenant, free from all charges, assessments,
impositions, expenses, deductions of any and every kind or nature whatsoever. Tenant
shall, at Tenant’s sole cost and expense, maintain the landscaping and parking lot, and make all additional repairs and alterations
as required to maintain the Premises consistent with Tenant’s practices at other facilities.

 

    7

     

    

 

5.4.          
Security Deposit. On or before the Execution Date of this Lease, Tenant shall deposit with Landlord the initial installment
of the Security Deposit as set forth in Section 2.2, which sum shall be held by Landlord as security for the faithful performance
by Tenant of all of the terms, covenants and conditions of this Lease to be kept and performed by Tenant during the Term. Interest
shall accrue on the Security Deposit for the benefit of Tenant and shall be paid to Tenant to the extent that Tenant is entitled
to the return of the Security Deposit as provided in this Lease. Landlord shall not be required to maintain a separate account
for the Security Deposit, but may intermingle it with other funds of Landlord; provided however, Landlord shall keep the Security
Deposit in a federally insured, interest-bearing account for the benefit of Tenant. If Tenant Defaults with respect to any provision
of this Lease, then without notice to Tenant, Landlord may (but shall not be required to), apply all or any part of the Security
Deposit for the payment of any Rent or any other sum in Default. If any portion of the Security Deposit is so used or applied,
then Tenant shall, upon demand therefor, restore the Security Deposit to its original amount. So long as no default has occurred
and is continuing, the unapplied portion of the Security Deposit shall be returned to Tenant, or, at Landlord’s option, to
the last assignee of Tenant’s interest hereunder, within sixty (60) days following the expiration of the Term. Tenant hereby
irrevocably waives and relinquishes any and all rights, benefits, or protections, if any, Tenant now has, or in the future may
have under any provision of law which (a) establishes the time frame by which a landlord must refund a security deposit under
a lease, or (b) provides that a landlord may claim from a security deposit only those sums reasonably necessary to remedy
defaults in the payment of rent, to repair damage caused by a tenant, or to clean the subject premises. Tenant acknowledges and
agrees that (x) any statutory time frames for the return of a security deposit are superseded by the express period identified
in this Section 5.4, and (y) rather than be so limited, Landlord may claim from the Security Deposit (i) any
and all sums expressly identified in this Section 5.4, and (ii) any additional sums reasonably necessary to compensate
Landlord for any and all losses or damages caused by Tenant’s default of this Lease, including, but not limited to, all damages
or rent due upon termination of this Lease. In the event of bankruptcy or other debtor-creditor proceedings against Tenant, the
Security Deposit shall be deemed to be applied first to the payment of Rent and other charges due Landlord for all periods prior
to the filing of such proceedings. 

 

5.5.           
No Discharge of Rent Obligations. Tenant’s obligation to pay Rent shall not be discharged or otherwise affected
by (a) any Applicable Laws now or hereafter applicable to the Premises, (b) any other restriction on Tenant’s use, (c) except
as expressly provided herein, any casualty or taking or (d) any other occurrence; and, except as expressly set forth herein, Tenant
waives all rights now or hereafter existing to terminate or cancel this Lease or quit or surrender the Premises or any part thereof,
or to assert any defense in the nature of constructive eviction to any action seeking to recover rent. Tenant’s obligation
to pay Rent with respect to any period or obligations arising, existing or pertaining to the period prior to the date of the expiration
or earlier termination of the Term or this Lease shall survive any such expiration or earlier termination; provided, however, that
nothing in this sentence shall in any way affect Tenant’s obligations with respect to any other period. Except as expressly
provided in this Lease, Tenant, to the extent now or hereafter permitted by Applicable Laws, waives all rights now or hereafter
conferred by statute or otherwise to quit, terminate or surrender this Lease or to any diminution, abatement or reduction of Rent
payable hereunder.

 

6.            
Use.

 

6.1.          
Use. Tenant shall use the Premises solely for the Permitted Use, and shall not use the Premises, or permit or suffer
the Premises to be used, for any other purpose without Landlord’s prior written consent, which consent Landlord may withhold
in its sole and absolute discretion. Tenant shall comply, and cause Tenant Parties to comply, with all Applicable Laws, zoning
ordinances and certificates of occupancy issued for the Premises or any portion thereof. Tenant shall not commit, or allow Tenant
Parties (as defined below) to commit, any waste of the Premises. Except in connection with the Permitted Use, Tenant shall not
do, or permit Tenant Parties to do, anything on or about the Premises that in any way increases the rate, or invalidates or prevents
the procuring, of any insurance protecting against loss or damage to any portion of the Premises or its contents, or against liability
for damage to property or injury to persons in or about any portion of the Premises. For purposes hereof, the term “Tenant
Parties“ means Tenant’s agents, contractors, subcontractors, employees, customers,
licensees, invitees, assignees and subtenants, and the term “Applicable Laws”
means all federal (to the extent not in direct conflict with applicable state, municipal or local cannabis licensing and program
laws, rules and regulations), state, municipal and local laws, codes, ordinances, rules and regulations of governmental authorities,
committees, associations, or other regulatory committees, agencies or governing bodies having jurisdiction over the Premises or
any portion thereof, Landlord or Tenant, including both statutory and common law, hazardous waste rules and regulations, and state
cannabis licensing and program laws, rules and regulations. Tenant may only place equipment within the Premises with floor loading
consistent with any building located on the Property’s structural design unless Tenant obtains Landlord’s prior written
approval. Tenant may place such equipment only in a location designed to carry the weight of such equipment.

 

    8

     

    

 

6.2.          
Legal Compliance. Notwithstanding any other provision herein to the contrary, Tenant shall be responsible for all
improvements or alterations required to be made and all liabilities, costs and expenses arising out of or in connection with the
compliance of the Premises with Applicable Laws including, without limitation, the Americans with Disabilities Act, 42 U.S.C. §
12101, et seq., and any state and local accessibility laws, codes, ordinances and rules (collectively, and together with regulations
promulgated pursuant thereto, the “ADA”), and Tenant shall indemnify, save,
defend (at Landlord’s option and with counsel reasonably acceptable to Landlord) and hold the Landlord Indemnitees harmless
from and against any Claims arising out of any such failure of the Premises to comply with Applicable Laws including, without limitation,
the ADA.

 

6.3.          
Indemnification. Tenant shall indemnify, save, defend (at Landlord’s option and with counsel reasonably acceptable
to Landlord) and hold Landlord and its affiliates, lenders, employees, agents and contractors (collectively, the “Landlord
Indemnitees”) harmless from and against any and all demands, claims, liabilities, losses,
costs, expenses, criminal or civil actions, forfeiture seizures, causes of action, damages, suits or judgments, and all reasonable
expenses (including reasonable attorneys’ fees, charges and disbursements, regardless of whether the applicable demand, claim,
action, cause of action or suit is voluntarily withdrawn or dismissed) incurred in investigating or resisting the same (collectively,
“Claims”) of any kind or nature that arise before, during or after the Term
as a result of Tenant’s breach of this Section 6.

 

6.4.          
Right to Finance. Tenant shall have the right to obtain leasehold or other financing to finance any improvements,
fixtures, equipment, or inventory at the Property that are owned by the Tenant (collectively, “Tenant Collateral”).
In connection with such financing, Landlord shall, and shall cause its fee mortgagee to execute an agreement, the terms of which
shall be reasonably acceptable to Landlord, pursuant to which Landlord and Landlord’s lender agree to subordinate or waive
any and all security and lien rights in the Tenant Collateral and grant Tenant’s lender the right to access the Property
to inspect, remove, protect, or otherwise exercise its rights with respect to the Tenant Collateral.

 

6.5.          
State and Local Cannabis Operator Approvals. Following the Commencement Date, Tenant shall use commercially reasonable
and diligent efforts to pursue and obtain, as soon as reasonably practicable, and thereafter maintain all permits, licenses, approvals
and authorizations required by applicable laws (except solely with respect to any federal law that directly conflicts with state
and local cannabis laws, regulations and ordinances) to cultivate and process cannabis plant parts and resins into products and
store the same for transport, in accordance with such licenses and approvals (collectively, the “State and Local Cannabis
Operator Approvals”). 

 

7.             
Hazardous Materials. 

 

7.1.          
Tenant shall not cause or permit any Hazardous Materials (as defined below) to be brought upon, kept or used in or about
the Premises in violation of Applicable Laws by Tenant or any Tenant Party. If (a) Tenant breaches such obligation, (b) the presence
of Hazardous Materials as a result of such a breach results in contamination of the Premises, any portion thereof, or any adjacent
property, (c) contamination of the Premises otherwise occurs during the Term or any extension or renewal hereof or holding over
hereunder or (d) contamination of the Premises occurs as a result of Hazardous Materials that are placed on or under or are released
into the Premises by a Tenant Party, then Tenant shall indemnify, save, defend (at Landlord’s option and with counsel reasonably
acceptable to Landlord) and hold the Landlord Indemnitees harmless from and against any and all Claims of any kind or nature, including
(w) diminution in value of the Premises or any portion thereof, (x) damages for the loss or restriction on use of rentable or usable
space or of any amenity of the Premises, (y) damages arising from any adverse impact on marketing of space in the Premises or any
portion thereof and (z) sums paid in settlement of Claims that arise before, during or after the Term as a result of such breach
or contamination. This indemnification by Tenant includes costs incurred in connection with any investigation of site conditions
or any clean-up, remedial, removal or restoration work required by any governmental authority because of Hazardous Materials present
in the air, soil or groundwater above, on, under or about the Premises. Without limiting the foregoing, if the presence of any
Hazardous Materials in, on, under or about the Premises, any portion thereof or any adjacent property caused or permitted by any
Tenant Party results in any contamination of the Premises, any portion thereof or any adjacent property, then Tenant shall promptly
take all actions at its sole cost and expense as are necessary to return the Premises, any portion thereof or any adjacent property
to its respective condition existing prior to the time of such contamination; provided that Landlord’s written approval of
such action shall first be obtained, which approval Landlord shall not unreasonably withhold; and provided, further, that it shall
be reasonable for Landlord to withhold its consent if such actions could have a material adverse long-term or short-term effect
on the Premises, any portion thereof or any adjacent property. Tenant’s obligations under this Section shall not be limited
by any limitation on the amount or type of damages, compensation or benefits payable by or for Tenant under workers’ compensation
acts, disability benefit acts, employee benefit acts or similar legislation.

 

    9

     

    

 

7.2.           
Landlord acknowledges that it is not the intent of this Section 7 to prohibit Tenant from operating its business
for the Permitted Use, and, in furtherance thereof (and notwithstanding the foregoing), Tenant may handle, use, store, and dispose
of products containing small quantities of Hazardous Materials to the extent customary, required and necessary for the Permitted
Use; subject to the provisions of this Section 7. Tenant may operate its business according to the custom of Tenant’s
industry so long as the use or presence of Hazardous Materials is strictly and properly monitored in accordance with Applicable
Laws. As a material inducement to Landlord to allow Tenant to use Hazardous Materials in connection with its business, Tenant agrees
to deliver to Landlord the following, to the extent related to Tenant’s operation at the Property (a) a list identifying
each type of Hazardous Material to be present at the Premises that is subject to regulation under any environmental Applicable
Laws in the form of a Tier II form pursuant to Section 312 of the Emergency Planning and Community Right-to-Know Act of 1986 (or
any successor statute) or any other form reasonably requested by Landlord, (b) a list of any and all approvals or permits from
governmental authorities required in connection with the presence of such Hazardous Material at the Premises and (c) correct and
complete copies of notices of violations of Applicable Laws related to Hazardous Materials (collectively, “Hazardous
Materials Documents”). Tenant shall deliver to Landlord updated Hazardous Materials Documents,
within fourteen (14) days after receipt of a written request therefor from Landlord, not more often than once per year, unless
(m) there are any changes to the Hazardous Materials Documents or (n) Tenant initiates any Alterations or changes its business,
in either case in a way that involves any material increase in the types or amounts of Hazardous Materials. In the event that a
review of the Hazardous Materials Documents indicates non-compliance with this Lease or Applicable Laws, Tenant shall, at its expense,
diligently take steps to bring its storage and use of Hazardous Materials into compliance. Notwithstanding anything in this Lease
to the contrary or Landlord’s review into Tenant’s Hazardous Materials Documents or use or disposal of hazardous materials,
however, Landlord shall not have and expressly disclaims any liability related to Tenant’s or other tenants’ use or
disposal of Hazardous Materials, it being acknowledged by Tenant that Tenant is best suited to evaluate the safety and efficacy
of its Hazardous Materials usage and procedures.

 

7.3.          
Tenant represents and warrants to Landlord that Tenant is not nor has it been, in connection with the use, disposal or storage
of Hazardous Materials, (a) subject to a material enforcement order issued by any governmental authority or (b) required to take
any remedial action.

 

7.4.          
At any time, and from time to time, prior to the expiration of the Term, Landlord shall have the right to conduct appropriate
tests of the Premises or any portion thereof to demonstrate that Hazardous Materials are present or that contamination has occurred
due to the acts or omissions of a Tenant Party, the cost of which shall be an Operating Expense. 

 

7.5.          
If underground or other storage tanks storing Hazardous Materials installed or utilized by Tenant are located on the Premises,
or are hereafter placed on the Premises by Tenant (or by any other party, if such storage tanks are utilized by Tenant), then Tenant
shall monitor the storage tanks, maintain appropriate records, implement reporting procedures, properly close any underground storage
tanks, and take or cause to be taken all other steps necessary or required under the Applicable Laws. 

 

    10

     

    

 

7.6.          
Tenant shall promptly report to Landlord any actual or suspected presence of mold or water intrusion at the Premises.

 

7.7.          
Tenant’s obligations under this Section 7 shall survive the expiration or earlier termination of the Lease.
During any period of time needed by Tenant or Landlord after the termination of this Lease to complete the removal from the Premises
of any such Hazardous Materials, Tenant shall be deemed a holdover tenant and subject to the provisions of Section 4.3.

 

7.8.          
As used herein, the term “Hazardous Material” means any toxic, explosive,
corrosive, flammable, infectious, radioactive, carcinogenic, mutagenic or otherwise hazardous substance, material or waste that
is or becomes regulated by Applicable Laws or any governmental authority.

 

8.             
Alterations.

 

8.1.         
Tenant shall not make any alterations, additions or improvements in or to the Premises
or engage in any construction, demolition, reconstruction, renovation or other work (whether major or minor) of any kind in, at
or serving the Premises (“Alterations”),
without obtaining Landlord’s prior written consent, except Tenant may make non-structural Alterations to the interior of
any building hereafter located on the Premises (excluding the roof) without such consent, but upon at least five (5) days’
prior notice to Landlord (except with respect to any Emergency Alteration, as defined below), provided that the cost thereof does
not exceed Two Hundred Thousand Dollars ($200,000.00) per occurrence or an aggregate amount of Five Hundred Thousand Dollars ($500,000.00)
annually. Notwithstanding the foregoing, Tenant will not do anything that could have a material adverse effect on any
improvements located on the Property (including any building hereafter located thereon) or
any life safety systems, without obtaining Landlord’s prior written consent. Furthermore, notwithstanding the foregoing,
in the event that a condition arises which Tenant reasonably believes (a) will cause or result in imminent damage to property or
imminent bodily injury or death to any person(s); and/or (b) will have an imminent material adverse effect on Tenant’s License
and/or operations at the Property (each, an “Emergency Condition”),
unless, in either case, Tenant undertakes certain Alterations (collectively, “Emergency Alterations”)
to remedy such Emergency Condition, Tenant shall not be required to provide Landlord with five (5) days’ prior notice of,
or obtain Landlord’s prior consent to, such Emergency Alterations, provided that (i) such Emergency Alterations will not
have a material adverse effect on any improvements located on the Property (including
any building hereafter located thereon) or any life safety systems; (ii) Tenant shall promptly notify Landlord (which notice may
be telephonic) of such Emergency Condition and the need for Emergency Alterations as soon as reasonably practicable; (iii) any
Emergency Alterations undertaken by Tenant without such prior notice to or consent from Landlord are (A) limited to those Alterations
that are reasonably necessary or prudent to remedy or alleviate such Emergency Condition, and (B) otherwise performed in accordance
with the terms and conditions of this Section. In the event that Landlord’s prior consent is required for any Alterations,
Landlord shall use its best efforts to respond to a request for such consent as soon as reasonably practicable and in any event
within ten (10) Business Days of Landlord’s receipt of Tenant’s written request. In the event Landlord fails to respond
to Tenant’s request within such ten (10) Business Day period, Landlord shall be deemed to have approved such request. All
alterations and improvements shall be properly permitted and installed at Tenant’s sole cost, by a licensed contractor, in
a good and workmanlike manner, and in conformity with all Applicable Laws. Any Alterations that Tenant shall desire to make and
which require the consent of Landlord shall be presented to Landlord in written form with detailed plans if required in order to
obtain governmental permits. Tenant shall: (a) acquire all applicable governmental permits; (b) furnish Landlord with copies
of both the permits and the plans and specifications at least ten (10) business days before the commencement of the work, and (c) comply
with all conditions of said permits in a prompt and expeditious manner. Any alterations shall be performed in a workmanlike manner
with good and sufficient materials. Upon completion of any Alterations, Tenant shall promptly upon completion furnish Landlord
with a reproducible copy of as-built drawings and specifications for any Alterations. Any proposed Alterations not objected to
by Landlord within ten (10) business days after receipt of notice of such Alterations and such other information as reasonably
requested by Landlord with respect to such Alterations, shall be deemed approved by Landlord. Notwithstanding anything contained
in this Lease to the contrary, Landlord shall not unreasonably withhold its consent to any Alterations that Tenant reasonably deems
necessary in order for Tenant to maintain the License in accordance with the Permitted Use and Applicable Law, even if building
or other permits are required to be issued for completion of such Alterations. 

 

    11

     

    

 

8.2.          
At least twenty (20) days prior to commencing any work relating to any Alterations
requiring the approval of Landlord that have been so approved, Tenant shall notify Landlord in writing of the expected date of
commencement. Prior to commencement of any Alterations, Tenant shall deliver to Landlord certificates of insurance evidencing Tenant’s
compliance with the insurance requirements set forth in Exhibit E of this Lease. Tenant shall pay, when due, all claims
for labor or materials furnished to or for Tenant for use in improving the Premises. Tenant shall not permit any mechanics’
or materialmen’s liens to be levied against the Premises arising out of work performed, materials furnished, or obligations
to have been performed on the Premises by or at the request of Tenant. Tenant shall indemnify, save, defend (at Landlord’s
option and with counsel reasonably acceptable to Landlord) and hold Landlord Indemnitees from and against any and all Claims of
any kind or nature that arise before, during or after the Term on account of claims of lien
of laborers or materialmen or others for work performed or materials or supplies furnished for Tenant or its contractors, agents
or employees. If Tenant fails to discharge or undertake to defend against such liability,
upon receipt of written notice from Landlord of such failure, Tenant shall have fifteen (15) days (the “Defense
Cure Period”) to cure such failure by prosecuting such a defense. If Tenant fails to do
so within the Defense Cure Period, then Landlord may settle the same and Tenant’s liability to Landlord shall be conclusively
established by such settlement provided that such settlement is entered into on commercially reasonable terms and conditions, the
amount of such liability to include both the settlement consideration and the costs and expenses (including reasonable attorneys’
fees) incurred by Landlord in effecting such settlement. In the event any contractor, agent or employee notifies Tenant of its
intent to file a mechanics’ or materialmen’s lien against the Premises, Tenant shall immediately notify Landlord of
such intention to file a lien or a lawsuit with respect to such lien. 

 

8.3.          
Tenant shall repair any damage to the Premises caused by Tenant’s removal of
any property from the Premises. During any such restoration period, Tenant shall pay Rent to Landlord as provided herein as if
such space were otherwise occupied by Tenant. The provisions of this Section shall survive the expiration or earlier termination
of this Lease.

 

8.4.          
The Premises plus any Alterations, attached equipment, decorations, fixtures and trade
fixtures; movable casework and related appliances; and other additions and improvements attached to or built into the Premises
made by either of the parties (including all floor and wall coverings; paneling; sinks and related plumbing fixtures; attached
benches; production equipment; walk-in refrigerators; ductwork; conduits; electrical panels and circuits; attached machinery and
equipment; and built-in furniture and cabinets, in each case, together with all additions and accessories thereto), shall (unless,
prior to such construction or installation, Landlord elects otherwise in writing) at all times remain the property of Landlord,
shall remain in the Premises and shall (unless, prior to construction or installation thereof, Landlord elects otherwise in writing)
be surrendered to Landlord upon the expiration or earlier termination of this Lease. For the avoidance of doubt, the items listed
on Exhibit B attached hereto (which Exhibit B may be updated by Tenant from and after the Commencement Date, subject
to Landlord’s written consent) constitute Tenant’s property (the “Tenant
Property”) and shall be removed by Tenant upon the expiration or earlier termination of
the Lease.

 

8.5.          
If Tenant shall fail to remove any of its property from the Premises prior to the
expiration of the Term, then Landlord may, at its option, remove the same in any manner that Landlord shall choose and store such
effects without liability to Tenant for loss thereof or damage thereto, and Tenant shall pay Landlord, upon demand, any costs and
expenses incurred due to such removal and storage or Landlord may, at its sole option and without notice to Tenant, sell such property
or any portion thereof at private sale and without legal process for such price as Landlord may obtain and apply the proceeds of
such sale against any (a) amounts due by Tenant to Landlord under this Lease and (b) any expenses incident to the removal, storage
and sale of such personal property.

 

8.6.          
Tenant shall reimburse Landlord for all third-party costs actually incurred by Landlord in connection with any Alterations,
including Landlord’s third-party costs for plan review, engineering review, coordination,
scheduling and supervision thereof.

 

8.7.          
Tenant shall require its contractors and subcontractors performing work on the Premises
to name Landlord and its affiliates and any lender as additional insureds on their respective insurance policies.

 

8.8.          
Tenant shall be entitled to install, maintain (and replace, from time to time) illuminated building signage at its sole
cost and expense, subject to approval by any applicable local authorities and conformance with all Applicable Laws. 

 

    12

     

    

 

9.            
Odors and Fumes. Except for odors and fumes that are consistent with the Prior Course of Dealing and which, in any
event, are not otherwise a violation of any Applicable Laws or CC&Rs, Tenant shall not
cause or permit (or conduct any activities that would cause) any release of any odors or fumes of any kind from the Premises. Tenant
shall, at Tenant’s sole cost and expense, provide odor eliminators and other devices (such as filters, air cleaners, scrubbers
and whatever other equipment may in Landlord’s judgment be necessary or appropriate from time to time) to abate any odors,
fumes or other substances in Tenant’s exhaust stream that emanate from Tenant’s Premises to a commercially reasonable
level consistent with the Permitted Use. Any work Tenant performs under this Section shall constitute Alterations. Tenant’s
responsibility to remove, eliminate and abate odors, fumes and exhaust shall continue throughout the Term. 

 

10.          
Repairs and Maintenance. 

 

10.1.        
Care of Premises. This Lease shall be deemed and construed to be an “absolute net lease.” Tenant shall,
at its sole cost and expense, keep the Premises in a working, neat, clean, sanitary, safe condition and repair, and shall keep
the Premises free from trash. Tenant shall make all repairs or replacements thereon or thereto, whether ordinary or extraordinary.
Without limiting the foregoing, Tenant’s obligations hereunder shall include the maintenance, repair and replacement of the
foundation, roof (including roof membrane), walls and all other structural components of any building located on the Property;
all heating, ventilation, air conditioning, plumbing, electrical, mechanical, utility and safety systems serving any building located
on the Property or Premises; the parking areas, roads and driveways located on the Premises; maintenance of exterior areas such
as gardening and landscaping; snow removal and signage; maintenance and repair of flashings, gutters, downspouts, roof drains,
skylights and waterproofing; and painting. Landlord shall not be required to furnish any services or facilities or to make any
repairs, replacements or alterations of any kind in or on the Premises. Tenant shall receive all invoices and bills relative to
the Premises and, except as otherwise provided herein, shall pay for all expenses directly to the person or company submitting
a bill without first having to forward payment for the expenses to Landlord. Tenant hereby expressly waives the right to make repairs
at the expense of Landlord as provided for in any Applicable Laws in effect at the time of execution of this Lease, or in any other
Applicable Laws that may hereafter be enacted, and waives its rights under Applicable Laws relating to a landlord’s duty
to maintain its premises in a tenantable condition. 

 

10.2.        
Service Contracts and Invoices. Tenant shall, promptly upon Landlord’s written request therefor, provide Landlord
with copies of all service contracts relating to the Tenant’s maintenance of the Premises and invoices received from Tenant
from such service providers. 

 

10.3.        
Action by Landlord if Tenant Fails to Maintain. If Tenant refuses or
neglects to repair or maintain (or commence and pursue the process of repairing or maintaining) the Premises as required hereunder
to the reasonable satisfaction of Landlord, Landlord, at any time following ten (10) business days from the date on which Landlord
shall make written demand on Tenant to affect such repair or maintenance, may, but shall not have the obligation to, make such
repair and/or maintenance (without liability to Tenant for any loss or damage which may occur to Tenant’s merchandise, fixtures
or other personal property, or to Tenant’s business by reason thereof) and upon completion thereof, Tenant shall pay to Landlord
as Landlord Additional Rent Landlord’s costs for making such repairs, plus interest at the Default Rate from the date of
expenditure by Landlord upon demand therefor. Moreover, Tenant’s failure to pay any of the charges in connection with the
performance of its maintenance and repair obligations under this Lease will constitute a material default under the Lease.

 

10.4.        
No Rent Abatement. There shall be no abatement of Rent and no liability of Landlord by reason of any injury to or
interference with Tenant’s business arising from the making of any repairs, alterations or improvements in or to any portion
of the Premises, or in or to improvements, fixtures, equipment and personal property therein, except that any such activity shall
in all events only be undertaken in accordance with this Lease and Applicable Laws. 

 

10.5.        
Right of Entry. Subject to Applicable Laws, Landlord and Landlord’s agents shall have the right to enter upon
the Premises or any portion thereof for the purposes of performing any repairs or maintenance Landlord is permitted to make pursuant
to this Lease, and of ascertaining the condition of the Premises or whether Tenant is observing and performing Tenant’s obligations
hereunder, all without unreasonable interference from Tenant or Tenant Parties. Except for emergency maintenance or repairs, the
right of entry contained in this paragraph shall be exercisable during business hours with not less than 24 hours prior notice,
and subject to Tenant’s authorized personnel accompanying Landlord’s agents in all areas of the Premises.

 

    13

     

    

 

11.          
Liens. Tenant shall keep the Premises free from any liens arising out of work or services performed, materials furnished
to or obligations incurred by Tenant, or, in the alternative, Tenant may bond over any liens to the reasonable satisfaction of
Landlord. Tenant further covenants and agrees that any mechanic’s or materialman’s lien filed against the Premises
for work or services claimed to have been done for, or materials claimed to have been furnished to, or obligations incurred by
Tenant shall be discharged or bonded by Tenant within twenty (20) days after the filing thereof, at Tenant’s sole cost and
expense. Should Tenant fail to discharge or bond against any lien of the nature described in this Section, Landlord may, at Landlord’s
election, pay such claim or otherwise provide security to eliminate the lien as a claim against title, and Tenant shall immediately
reimburse Landlord for the costs thereof as Additional Rent. Tenant shall indemnify, save, defend (at Landlord’s option and
with counsel reasonably acceptable to Landlord) and hold the Landlord Indemnitees harmless from and against any Claims arising
from any such liens, including any administrative, court or other legal proceedings related to such liens. In the event that Tenant
leases or finances the acquisition of office equipment, furnishings or other personal property of a removable nature utilized by
Tenant in the operation of Tenant’s business, Tenant warrants that any Uniform Commercial Code financing statement shall,
upon its face or by exhibit thereto, indicate that such financing statement is applicable only to removable personal property of
Tenant located within the Premises.

 

12.          
CC&Rs. This Lease is subject to any recorded easements, covenants, conditions and restrictions on the Property
or Premises, as the same may be amended, amended and restated, supplemented or otherwise modified from time to time (the “CC&Rs”).
Tenant shall, at its sole cost and expense, comply with the CC&Rs, including any obligations of Landlord thereunder as the
owner of the Property, and Landlord shall cooperate (at no cost to Landlord) with any efforts by Tenant in connection therewith.
Tenant shall promptly notify Landlord of any alleged defaults under the CC&Rs. For the avoidance of doubt and notwithstanding
any provision herein to the contrary, there shall be no abatement of Rent and no liability of Landlord by reason of any injury
to or interference with Tenant’s business arising from the CC&Rs and/or the exercise of any rights or obligations thereunder.

 

13.          
Utilities and Services. Tenant shall make all arrangements for and pay for
all water, sewer, gas, heat, light, power, telephone service and any other service or utility Tenant requires at the Premises.
Landlord shall not be liable for any failure or interruption of any utility service being furnished to the Premises, and no such
failure or interruption shall entitle Tenant to any abatement or right to terminate this Lease. In the event that any utilities
are furnished by Landlord, Tenant shall pay to Landlord the cost thereof as an Operating Expense.

 

14.          
Estoppel Certificate. Tenant shall, within ten (10) business days after receipt of written notice from Landlord,
execute, acknowledge and deliver a statement in writing substantially in the form attached to this Lease as Exhibit C, or
on any other form reasonably requested by a current or proposed lender or encumbrancer or proposed purchaser, (a) certifying that
this Lease is unmodified and in full force and effect (or, if modified, stating the nature of such modification and certifying
that this Lease as so modified is in full force and effect) and the dates to which rental and other charges are paid in advance,
if any, (b) acknowledging that there are not, to Tenant’s knowledge, any uncured defaults on the part of Landlord hereunder,
or specifying such defaults if any are claimed, and (c) setting forth such further information with respect to this Lease or the
Premises as may be reasonably requested thereon. Each Guarantor shall, within ten (10) days after receipt of written notice from
Landlord, execute, acknowledge and deliver a statement in writing in the same form. Tenant’s or any Guarantor’s failure
to deliver any such statement within such the prescribed time shall, at Landlord’s option, constitute a Default (as defined
below) under this Lease, and, in any event, shall be binding upon Tenant or such Guarantor (as applicable) that the Lease and such
Guaranty are in full force and effect and without modification except as may be represented by Landlord in any certificate prepared
by Landlord and delivered to Tenant or such Guarantor (as applicable) for execution.

 

15.          
Assignment or Subletting. 

 

15.1.          
None of the following (each, a “Transfer”), either voluntarily or by
operation of Applicable Laws, shall be directly or indirectly performed without Landlord’s prior written consent: (a) Tenant
selling, hypothecating, assigning, pledging, encumbering or otherwise transferring this Lease or subletting the Premises or (b)
a controlling interest in Tenant being sold, assigned or otherwise transferred (other than as a result of shares in Tenant being
sold on a public stock exchange). For purposes of the preceding sentence, “control” means (x) owning (directly or indirectly)
more than fifty percent (50%) of the stock or other equity interests of another person or (y) possessing, directly or indirectly,
the power to direct or cause the direction of the management and policies of such person. 

 

    14

     

    

 

15.2.        
In the event Tenant desires to effect a Transfer, then, at least thirty (30) but not more than ninety (90) days prior to
the date when Tenant desires the Transfer to be effective (the “Transfer Date”),
Tenant shall provide written notice to Landlord (the “Transfer Notice”) containing
information (including references) concerning the character of the proposed transferee, assignee or sublessee; the proposed Transfer
Date; the most recent unconsolidated financial statements of Tenant and of the proposed transferee, assignee or sublessee (“Required
Financials”); any ownership or commercial relationship between Tenant and the proposed
transferee, assignee or sublessee; and the consideration and all other material terms and conditions of the proposed Transfer,
all in such detail as Landlord shall reasonably require. In no event shall Landlord be deemed to be unreasonable for declining
to consent to a Transfer to a transferee, assignee or sublessee of poor reputation, lacking financial qualifications or seeking
a change in the Permitted Use, or jeopardizing directly or indirectly the status of Landlord or any of Landlord’s affiliates
as a Real Estate Investment Trust under the Internal Revenue Code of 1986, as amended from time to time. 

 

15.3.        
The following are conditions precedent to a Transfer or to Landlord considering a request by Tenant to a Transfer:

 

15.3.1.     
Tenant shall remain fully liable under this Lease, and each Guarantor shall continue to remain fully liable under such Guarantor’s
Guaranty, including with respect to the Term after the Transfer Date. Tenant agrees that it shall not be (and shall not be deemed
to be) a guarantor or surety of this Lease, however, and waives its right to claim that it is a guarantor or surety or to raise
in any legal proceeding any guarantor or surety defenses permitted by this Lease or by Applicable Laws;

 

15.3.2.     
Tenant shall reimburse Landlord for Landlord’s actual third-party costs and expenses, including reasonable attorneys’
fees, charges and disbursements incurred in connection with the review, processing and documentation of such request, in an amount
not to exceed Five Thousand Dollars ($5,000.00);

 

15.3.3.     
If Tenant’s transfer of rights or sharing of the Premises provides for the receipt by, on behalf of or on account
of Tenant of any consideration of any kind whatsoever (including a premium rental for a sublease or lump sum payment for an assignment)
in excess of the rental and other charges due to Landlord under this Lease, Tenant shall be entitled to retain one hundred percent
(100%) of all of such excess;

 

15.3.4.     
The proposed transferee, assignee or sublessee shall agree that, in the event Landlord gives such proposed transferee, assignee
or sublessee notice that Tenant is in default under this Lease, such proposed transferee, assignee or sublessee shall thereafter
make all payments otherwise due Tenant directly to Landlord, which payments shall be received by Landlord without any liability
being incurred by Landlord, except to credit such payment against those due by Tenant under this Lease, and any such proposed transferee,
assignee or sublessee shall agree to attorn to Landlord or its successors and assigns should this Lease be terminated for any reason;
provided, however, that in no event shall Landlord or its Lenders, successors or assigns be obligated to accept such attornment;

 

15.3.5.     
Tenant shall not then be in default hereunder in any respect;

 

15.3.6.     
Such proposed transferee, assignee or sublessee’s use of the Premises shall be the same as the Permitted Use, unless
otherwise approved by Landlord;

 

15.3.7.     
Landlord shall not be bound by any provision of any agreement pertaining to the Transfer, except for Landlord’s written
consent to the same;

 

15.3.8.     
Tenant shall pay all transfer and other taxes (including interest and penalties) assessed or payable for any Transfer;

 

    15

     

    

 

15.3.9.     
Landlord’s consent (or waiver of its rights) for any Transfer shall not waive Landlord’s right to consent or
refuse consent to any later Transfer; and

 

15.3.10.  
Tenant shall deliver to Landlord a list of Hazardous Materials (as defined below), certified by the proposed transferee,
assignee or sublessee to be true and correct, that the proposed transferee, assignee or sublessee intends to use or store in the
Premises. Additionally, Tenant shall deliver to Landlord, on or before the date any proposed transferee, assignee or sublessee
takes occupancy of the Premises, all of the items relating to Hazardous Materials of such proposed transferee, assignee or sublessee
as described in Section 7.

 

15.4.        
Any Transfer that is not in compliance with the provisions of this Section or with respect to which Tenant does not fulfill
its obligations pursuant to this Section shall be void and shall, at the option of Landlord, terminate this Lease.

 

15.5.        
Notwithstanding any Transfer, Tenant shall remain fully and primarily liable for the payment of all Rent and other sums
due or to become due hereunder, and for the full performance of all other terms, conditions and covenants to be kept and performed
by Tenant. The acceptance of Rent or any other sum due hereunder, or the acceptance of performance of any other term, covenant
or condition thereof, from any person or entity other than Tenant shall not be deemed a waiver of any of the provisions of this
Lease or a consent to any Transfer.

 

15.6.        
Notwithstanding anything to the contrary contained herein, Tenant may, at any time and from time to time, without the consent
of Landlord, assign this Lease or any interest hereunder to, or sublease or license the Premises or any part thereof to (each of
the following is referred to herein as a “Permitted Transfer”): (a) any
successor entity of Tenant resulting from a merger, reorganization, or consolidation with Tenant (provided that such merger, reorganization
or consolidation is undertaken primarily for independent business purposes, and not primarily for purposes of transferring this
Lease or any interest in the Premises); (b) any initial public offering by Tenant or any or its affiliates, (c) any entity
succeeding to all or substantially all of the business and assets of Tenant (provided that such transaction is undertaken primarily
for independent business purposes, and not primarily for purposes of transferring this Lease or any interest in the Premises);
(d) any entity that, as of the date of determination, is an Affiliate of Tenant; or (e) any entity that, concurrently with such
Transfer, is acquiring all or substantially all of the business being conducted at the Premises by Tenant or its affiliates, provided
that (i) Tenant shall notify Landlord in writing at least twenty (20) days prior to the effectiveness of such Permitted Transfer,
(ii) Tenant shall provide Landlord with evidence reasonably satisfactory to Landlord that the Transfer qualifies as a Permitted
Transfer and shall otherwise comply with the requirements of this Lease regarding such Transfer, (iii) the transferee has a net
worth that is equal to or greater than the net worth of the transferring Tenant, and (iv) Tenant and each Guarantor (in accordance
with such Guarantor’s Guaranty) shall remain fully liable for the payment of all Rent and other sums due or to become due
hereunder, and for the full performance of all other terms, conditions and covenants to be kept and performed by Tenant. 

 

15.7.        
If Tenant sublets the Premises or any portion thereof, Tenant hereby immediately and irrevocably assigns to Landlord, as
security for Tenant’s obligations under this Lease, all rent from any such subletting, and appoints Landlord as assignee
and attorney-in-fact for Tenant, and Landlord (or a receiver for Tenant appointed on Landlord’s application) may collect
such rent and apply it toward Tenant’s obligations under this Lease; provided that, until the occurrence of a Default (as
defined below) by Tenant, Tenant shall have the right to collect such rent.

 

16.          
Indemnification and Exculpation. 

 

16.1.        
Tenant agrees to indemnify, save, defend (at Landlord’s option and with counsel reasonably acceptable to Landlord)
and hold the Landlord Indemnitees harmless from and against any and all Claims of any kind or nature, real or alleged, arising
from (a) injury to or death of any person or damage to any property occurring within or about the Premises arising directly or
indirectly out of the presence at or use or occupancy of the Premises or Project by a Tenant Party, (b) an act or omission on the
part of any Tenant Party, (c) a breach or default by Tenant in the performance of any of its obligations hereunder or (d) injury
to or death of persons or damage to or loss of any property, real or alleged, arising from the serving of any intoxicating substances
at the Premises or Project, except to the extent directly caused by Landlord’s gross negligence or willful misconduct. Tenant’s
obligations under this Section shall not be affected, reduced or limited by any limitation on the amount or type of damages, compensation
or benefits payable by or for Tenant under workers’ compensation acts, disability benefit acts, employee benefit acts or
similar legislation. Tenant’s obligations under this Section shall survive the expiration or earlier termination of this
Lease.

 

    16

     

    

 

16.2.        
Notwithstanding anything in this Lease to the contrary, Landlord shall not be liable to Tenant for and Tenant assumes all
risk of the following (except to the extent directly caused by Landlord or Landlord’s agents): (a) damage or losses caused
by fire, electrical malfunction, gas explosion or water damage of any type (including broken water lines, malfunctioning fire sprinkler
systems, roof leaks or stoppages of lines), and (b) damage to personal property (in each case, regardless of whether such damages
are foreseeable). Tenant further waives any claim for injury to Tenant’s business or loss of income relating to any such
damage or destruction of personal property as described in this Section. Notwithstanding anything in the foregoing or this Lease
to the contrary, neither Landlord nor Tenant shall be liable to the other for any form of special, indirect, consequential, or
punitive damages.

 

16.3.        
Landlord shall not be liable for any damages arising from any act, omission or neglect of any third party.

 

16.4.        
The provisions of this Section shall survive the expiration or earlier termination of this Lease.

 

17.          
Insurance; Waiver of Subrogation. 

 

17.1.        
Landlord shall maintain a policy or policies of insurance protecting Landlord against the following (all of which shall
be payable by Tenant as Operating Expenses):

 

17.1.1.     
Fire and other perils normally included within the classification of fire and extended coverage, together with insurance
against vandalism and malicious mischief, to the extent of the full replacement cost of the Premises,
including, at Landlord’s option, earthquake and flood coverage, exclusive of trade fixtures, equipment and improvements insured
by Tenant, with agreed value, full replacement and other endorsements which Landlord may elect to maintain; 

 

17.1.2.     
Twenty-four (24) months of rental loss insurance and to the extent of 100% of the gross rentals from the Premises; 

 

17.1.3.     
Comprehensive general liability insurance with a single limit of not less than $2,000,000 for
bodily injury or death and property damage with respect to the Premises, a general aggregate not less than $2,000,000 for bodily
injury or death and property damage with respect to the Premises, and not less than $4,000,000 of excess umbrella liability insurance;
and 

 

17.1.4.     
At Landlord’s sole option, environmental liability or environmental clean-up/remediation insurance in such amounts
and with such deductibles and other provisions as Landlord may determine in its sole and absolute discretion.

 

17.2.       
Tenant shall, at its own cost and expense, procure and maintain during the Term the following insurance for the benefit
of Tenant and Landlord (as their interests may appear) with insurers financially acceptable and lawfully authorized to do business
in the state where the Premises are located:

 

17.2.1.     
Commercial General Liability insurance on a broad-based occurrence coverage form, with coverages including but not limited
to bodily injury (including death), property damage (including loss of use resulting therefrom), premises/operations, personal
& advertising injury, and contractual liability with limits of liability of not less than $1,000,000 for bodily injury and
property damage per occurrence, $5,000,000 general aggregate, which limits may be met by use of excess and/or umbrella liability
insurance provided that such coverage is at least as broad as the primary coverages required herein.

 

17.2.2.     
Commercial Automobile Liability insurance covering liability arising from the use or operation of any auto, including those
owned, hired or otherwise operated or used by or on behalf of the Tenant. The coverage shall be on a broad-based occurrence form
with combined single limits of not less than $1,000,000 per accident for bodily injury and property damage.

 

    17

     

    

 

17.2.3.     
Commercial Property insurance covering property damage to the full replacement cost value and business interruption. Covered
property shall include all tenant improvements in the Premises (to the extent not insured by Landlord) and Tenant’s property
including personal property, furniture, fixtures, machinery, equipment, stock, inventory and improvements and betterments, which
may be owned by Tenant or Landlord and required to be insured hereunder, or which may be leased, rented, borrowed or in the care
custody or control of Tenant, or Tenant’s agents, employees or subcontractors. Such insurance, with respect only to all
Alterations or other work performed on the Premises by Tenant (collectively, “Tenant Work”),
shall name Landlord and Landlord’s current and future mortgagees as loss payees as their interests may appear. Such insurance
shall be written on an “all risk” of physical loss or damage basis including the perils of fire, extended coverage,
electrical injury, mechanical breakdown, windstorm, vandalism, malicious mischief, sprinkler leakage, back-up of sewers or drains,
flood, earthquake, terrorism and such other risks Landlord may from time to time designate, for the full replacement cost value
of the covered items with an agreed amount endorsement with no co-insurance. Business interruption coverage shall have limits
sufficient to cover Tenant’s lost profits and necessary continuing expenses, including rents due Landlord under the Lease.
The minimum period of indemnity for business interruption coverage shall be twelve (12) months plus twelve (12) months’
extended period of indemnity.

 

17.2.4.     
Workers’ Compensation insurance as is required by statute or law, or as may be available on a voluntary basis and
Employers’ Liability insurance with limits of not less than the following: each accident, Five Hundred Thousand Dollars ($500,000);
disease, Five Hundred Thousand Dollars ($500,000); disease (each employee), Five Hundred Thousand Dollars ($500,000).

 

17.2.5.     
Pollution Legal Liability insurance is required if Tenant stores, handles, generates or treats Hazardous Materials, as determined
solely by Landlord, on or about the Premises. Such coverage shall include bodily injury, sickness, disease, death or mental anguish
or shock sustained by any person; property damage including physical injury to or destruction of tangible property including the
resulting loss of use thereof, clean-up costs, and the loss of use of tangible property that has not been physically injured or
destroyed; and defense costs, charges and expenses incurred in the investigation, adjustment or defense of claims for such compensatory
damages. Coverage shall apply to both sudden and non-sudden pollution conditions including the discharge, dispersal, release or
escape of smoke, vapors, soot, fumes, acids, alkalis, toxic chemicals, liquids or gases, waste materials or other irritants, contaminants
or pollutants into or upon land, the atmosphere or any watercourse or body of water. Claims-made coverage is permitted, provided
the policy retroactive date is continuously maintained prior to the commencement date of this Lease, and coverage is continuously
maintained during all periods in which Tenant occupies the Premises. Coverage shall be maintained with limits of not less than
$1,000,000 per incident with a $2,000,000 policy aggregate and for a period of two (2) years thereafter.

 

17.3.        
During all construction by Tenant at the Premises, with respect to tenant improvements being constructed (including any
Alterations), Tenant shall cause the insurance required in Exhibit E to be in place.

 

17.4.        
The insurance required of Tenant by this Section shall be with companies at all times having a current rating of not less
than A- and financial category rating of at least Class VII in “A.M. Best’s Insurance Guide” current edition.
Tenant shall obtain for Landlord from the insurance companies/broker or cause the insurance companies/broker to furnish certificates
of insurance evidencing all coverages required herein to Landlord. Landlord reserves the right to require complete, certified copies
of all required insurance policies including any endorsements. No such policy shall be cancelable or subject to reduction of coverage
or other modification or cancellation except after twenty (20) days’ prior written notice to Landlord from Tenant or its
insurers (except in the event of non-payment of premium, in which case ten (10) days’ written notice shall be given). All
such policies shall be written as primary policies, not contributing with and not in excess of the coverage that Landlord may carry.
Tenant’s required policies shall contain severability of interests clauses stating that, except with respect to limits of
insurance, coverage shall apply separately to each insured or additional insured. Tenant shall, at least twenty-five (25) days
prior to the expiration of such policies, furnish Landlord with renewal certificates of insurance or binders. Tenant agrees that
if Tenant does not take out and maintain such insurance, Landlord may (but shall not be required to) procure such insurance on
Tenant’s behalf and at its cost to be paid by Tenant as Additional Rent. Commercial General Liability, Commercial Automobile
Liability, Umbrella Liability and Pollution Legal Liability insurance as required above shall name Landlord, IIP Operating Partnership,
LP and Innovative Industrial Properties, Inc. and their respective officers, employees, agents, general partners, members, subsidiaries,
affiliates and Lenders (“Landlord Parties”) as additional insureds as respects
liability arising from work or operations performed by or on behalf of Tenant, Tenant’s use or occupancy of Premises, and
ownership, maintenance or use of vehicles by or on behalf of Tenant.

 

    18

     

    

 

17.5.        
Tenant assumes the risk of damage to any fixtures, goods, inventory, merchandise, equipment and leasehold improvements,
and Landlord shall not be liable for injury to Tenant’s business or any loss of income therefrom, relative to such damage,
all as more particularly set forth within this Lease. Tenant shall, at Tenant’s sole cost and expense, carry such insurance
as Tenant desires for Tenant’s protection with respect to personal property of Tenant or business interruption.

 

17.6.        
Landlord and Tenant agree to waive (and Landlord and Tenant shall exercise commercially reasonable efforts to cause their
respective insurers to hereby waive) any and all rights of recovery or subrogation against the parties hereto with respect to any
loss, damage, claims, suits or demands, howsoever caused, that are covered, or should have been covered, by valid and collectible
insurance, including any deductibles or self-insurance maintained thereunder. If necessary, each of Tenant and Landlord, as applicable,
agrees to endorse the required insurance policies to permit waivers of subrogation as required hereunder and hold harmless and
indemnify the parties hereto for any loss or expense incurred as a result of a failure to obtain such waivers of subrogation from
insurers. Tenant, upon obtaining the policies of insurance required or permitted under this Lease (or Landlord, in the event Landlord
procures any applicable insurance required under this Lease), shall give notice to its insurance carriers that the foregoing waiver
of subrogation is contained in this Lease. If such policies shall not be obtainable with such waiver or shall be so obtainable
only at a premium over that chargeable without such waiver, then Tenant or Landlord, as applicable, shall notify the other party
of such conditions.

 

17.7.        
Landlord may require insurance policy limits required under this Lease to be raised to conform with requirements of Landlord’s
lender, if any.

 

17.8.        
Any costs incurred by Landlord pursuant to this Section shall be included as Operating Expenses payable by Tenant pursuant
to this Lease.

 

17.9.        
The provisions of this Section shall survive the expiration or earlier termination of this Lease.

 

18.           
Subordination and Attornment.

 

18.1.        
This Lease shall be subject and subordinate to the lien of any mortgage, deed of trust, or lease in which Landlord is tenant
now or hereafter in force against the Premises or any portion thereof and to all advances made or hereafter to be made upon the
security thereof without the necessity of the execution and delivery of any further instruments on the part of Tenant to effectuate
such subordination.

 

18.2.        
Notwithstanding the foregoing, Tenant shall execute and deliver upon demand such further instrument or instruments evidencing
such subordination of this Lease to the lien of any such mortgage or mortgages or deeds of trust or lease in which Landlord is
tenant as may be required by Landlord. If any such mortgagee, beneficiary or landlord under a lease wherein Landlord is tenant
(each, a “Mortgagee”) so elects, however, this Lease shall be deemed prior
in lien to any such lease, mortgage, or deed of trust upon or including the Premises regardless of date and Tenant shall execute
a statement in writing to such effect at Landlord’s request. 

 

18.3.        
In the event any proceedings are brought for foreclosure, or in the event of the exercise of the power of sale under any
mortgage or deed of trust made by Landlord covering the Premises, Tenant shall at the election of the purchaser at such foreclosure
or sale attorn to the purchaser upon any such foreclosure or sale and recognize such purchaser as Landlord under this Lease.

 

18.4.        
Notwithstanding anything herein to the contrary, in no event shall Landlord obtain financing or execute or enter into any
agreement affecting the Property if such action jeopardizes Tenant’s License or otherwise unreasonably interferes with the
Permitted Use in any material respect.

 

    19

     

    

 

19.           
Defaults and Remedies.

 

19.1.          Late
payment by Tenant to Landlord of Rent and other sums due shall cause Landlord to incur costs not contemplated by this Lease, the
exact amount of which shall be extremely difficult and impracticable to ascertain. Such costs include processing and accounting
charges and late charges that may be imposed on Landlord by the terms of any mortgage or trust deed covering the Premises. Therefore,
if any installment of Rent due from Tenant is not received by Landlord within three (3) days after the date such payment is due,
Tenant shall pay to Landlord (a) an additional sum of ten percent (10%) of the overdue Rent as a late charge plus (b) interest
at an annual rate (the “Default Rate”) equal to the lesser of (a)
fifteen percent (15%) and (b) the highest rate permitted by Applicable Laws. The parties agree that this late charge represents
a fair and reasonable estimate of the costs that Landlord shall incur by reason of late payment by Tenant and shall be payable
as Additional Rent to Landlord due with the next installment of Rent. Landlord’s acceptance of any Additional Rent (including
a late charge or any other amount hereunder) shall not be deemed an extension of the date that Rent is due or prevent Landlord
from pursuing any other rights or remedies under this Lease, at law or in equity.

 

19.2.        
No payment by Tenant or receipt by Landlord of a lesser amount than the Rent payment herein stipulated shall be deemed to
be other than on account of the Rent, nor shall any endorsement or statement on any check or any letter accompanying any check
or payment as Rent be deemed an accord and satisfaction, and Landlord may accept such check or payment without prejudice to Landlord’s
right to recover the balance of such Rent or pursue any other remedy provided in this Lease or in equity or at law. 

 

19.3.        
If Tenant fails to pay any sum of money required to be paid by it hereunder or perform any other act on its part to be performed
hereunder, in each case within the applicable cure period (if any) described herein, then Landlord may (but shall not be obligated
to), without waiving or releasing Tenant from any obligations of Tenant, make such payment or perform such act. Notwithstanding
the foregoing, in the event of an emergency, Landlord shall have the right to enter the Premises and act in accordance with its
rights as provided elsewhere in this Lease. Tenant shall pay to Landlord as Additional Rent all sums so paid or incurred by Landlord,
together with interest at the Default Rate, computed from the date such sums were paid or incurred.

 

19.4.        
The occurrence of any one or more of the following events shall constitute a “Default”
hereunder by Tenant:

 

19.4.1.     
Tenant abandons or vacates the Premises while failing to make payments of Rent when due or providing for the on-going maintenance
and repair of the Premises as required pursuant to the terms of this Lease;

 

19.4.2.     
Tenant fails to make any payment of Rent, as and when due, where such failure shall continue for a period of five (5) days
after written notice thereof from Landlord to Tenant;

 

19.4.3.     
Tenant fails to observe or perform any obligation or covenant contained herein (other than those enumerated in this Section
19.4) after the expiration of any applicable notice and cure period or if no such cure period is specified, within thirty (30)
days following Tenant’s receipt of written notice from Landlord advising Tenant of such failure, but if such failure is curable
but cannot reasonably be cured during such thirty (30) day period, and if Tenant has commenced such cure promptly and in any case
within such thirty (30) day period and thereafter has diligently pursued such cure to completion, then such thirty (30) day period
shall be extended to ninety (90) days;

 

19.4.4.     
Tenant makes an assignment for the benefit of creditors, or a receiver, trustee or custodian is appointed to or does take
title, possession or control of all or substantially all of Tenant’s or Guarantor’s assets;

 

19.4.5.     
Tenant or any Guarantor files a voluntary petition under the United States Bankruptcy Code or any successor statute (as
the same may be amended from time to time, the “Bankruptcy Code”)
or an order for relief is entered against Tenant or any Guarantor (as applicable) pursuant to a voluntary or involuntary proceeding
commenced under any chapter of the Bankruptcy Code;

 

19.4.6.     
Any involuntary petition is filed against Tenant or any Guarantor under any chapter of the Bankruptcy Code and is not dismissed
within one hundred twenty (120) days;

 

    20

     

    

 

19.4.7.     
A default exists under any Guaranty executed by a Guarantor in favor of Landlord, after the expiration of any applicable
notice and cure periods; 

 

19.4.8.     
Tenant’s interest in this Lease is attached, executed upon or otherwise judicially seized and such action is not released
within one hundred twenty (120) days of the action;

 

19.4.9.     
A governmental authority seizes any part of the Property seeking forfeiture, whether or not a judicial forfeiture proceeding
has commenced; 

 

19.4.10.  
A final, appealable judgment having the effect of establishing that Tenant’s operation violates Landlord’s contractual
obligations pursuant to any private covenants of record restricting the use of the Premises (including any building or other improvements
located thereon), provided such private covenant was not created by Landlord after the Execution Date without Tenant’s consent
(provided, however, that such Default under this Section 19.4.10 shall not be determined to have occurred until the exhaustion
of any appeal from such judgment, on the express conditions that Tenant (i) immediately ceases operations at the Property following
the issuance of the final, appealable judgment; (ii) thereafter is diligently pursuing an appeal of the judgment; and (iii) otherwise
continues to comply with the terms and conditions of the Lease); or 

 

19.4.11.  
An event occurs that results in any insurance carrier that provides insurance coverage with respect to any aspect of the
Project providing notice to the Landlord of its intent to cancel such insurance coverage, and Landlord, exercising commercially
reasonable efforts, is not able to procure comparable replacement insurance coverage that is reasonably acceptable to Landlord
prior to the actual cancellation date specified in the notice of the cancelling insurance carrier; or

 

19.4.12.  
The occurrence of a default by Tenant under the Development Agreement, after the expiration of any applicable notice and
cure periods.

 

19.5.        
Notices given under this Section shall specify the alleged default and shall demand that Tenant perform the provisions of
this Lease or pay the Rent that is in arrears, as the case may be, within the applicable period of time, or quit the Premises.
No such notice shall be deemed a forfeiture or a termination of this Lease unless Landlord elects otherwise in such notice. 

 

19.6.        
In the event of a Default by Tenant, and at any time thereafter, with or without notice or demand and without limiting Landlord
in the exercise of any right or remedy that Landlord may have under Applicable Laws or this Lease, Landlord has the right to do
any or all of the following:

 

19.6.1.     
Halt any Alterations and order Tenant’s contractors to stop work or halt any work being performed pursuant to the
terms of this Lease or the Development Agreement;

 

19.6.2.     
Terminate Tenant’s right to possession of the Premises by written notice to Tenant or by any lawful means, in which
case Tenant shall immediately surrender possession of the Premises to Landlord. In such event, Landlord shall have the immediate
right to re-enter and remove all persons and property (subject to Applicable Laws and excluding any Tenant Collateral), and such
property may be removed and stored elsewhere at the cost and for the account of Tenant, all without service of notice or resort
to legal process and without being deemed guilty of trespass or becoming liable for any loss or damage; and

 

19.6.3.     
Terminate this Lease, in which event Tenant shall immediately surrender possession of the Premises to Landlord. In such
event, Landlord shall have the immediate right to re-enter and remove all persons and property, and such property may be removed
and stored elsewhere at the cost and for the account of Tenant, all without service of notice or resort to legal process and without
being deemed guilty of trespass or becoming liable for any loss or damage. In the event that Landlord shall elect to so terminate
this Lease, then Landlord shall be entitled to recover from Tenant all damages incurred by Landlord by reason of Tenant’s
default, including:

 

    21

     

    

 

19.6.3.1.
The sum of: (i) the worth at the time of award (computed by allowing interest at the Default Rate) of any unpaid Rent that had
accrued at the time of such termination; plus (ii) the worth at the time of award of the amount by which the unpaid Rent that would
have accrued during the period commencing with termination of the Lease and ending at the time of award exceeds that portion of
the loss of Landlord’s rental income from the Premises that Tenant proves to Landlord’s reasonable satisfaction could
have been reasonably avoided; plus; (iii) the worth at the time of award of the amount by which the unpaid Rent for the balance
of the Term after the time of award exceeds that portion of the loss of Landlord’s rental income from the Premises that Tenant
proves to Landlord’s reasonable satisfaction could have been reasonably avoided; plus (iv) any other amount necessary to
compensate Landlord for all the detriment caused by Tenant’s failure to perform its obligations under this Lease or that
in the ordinary course of things would be likely to result therefrom, including the cost of restoring the Premises to the condition
required under the terms of this Lease, including any rent payments not otherwise chargeable to Tenant (e.g., during any “free”
rent period or rent holiday); plus (v) at Landlord’s election, such other amounts in addition to or in lieu of the foregoing
as may be permitted from time to time by Applicable Laws; or

 

19.6.3.2.
At Landlord’s election, as minimum liquidated damages in addition to any (i) amounts paid or payable to Landlord pursuant
to Section 19.6.3.1.(i) prior to such election and (ii) costs of restoring the Premises to the condition required under
the terms of this Lease, an amount (the “Election Amount”) equal to either
(A) the positive difference (if any, and measured at the time of such termination) between (1) the then-present value of the total
Rent and other benefits that would have accrued to Landlord under this Lease for the remainder of the Term if Tenant had fully
complied with the Lease minus (2) the then-present cash rental value of the Premises as determined by Landlord for what would be
the then-unexpired Term if the Lease remained in effect, computed using the discount rate of the Federal Reserve Bank of San Francisco
at the time of the award plus one (1) percentage point (the “Discount Rate”)
or (B) twelve (12) months (or such lesser number of months as may then be remaining in the Term) of Base Rent and Additional Rent
at the rate last payable by Tenant pursuant to this Lease, in either case as Landlord specifies in such election. Landlord and
Tenant agree that the Election Amount represents a reasonable forecast of the minimum damages expected to occur in the event of
a breach, taking into account the uncertainty, time and cost of determining elements relevant to actual damages, such as fair market
rent, time and costs that may be required to re-lease the Premises, and other factors; and that the Election Amount is not a penalty,
provided the foregoing liquidated damages are not intended to permit Landlord to recover duplicative damages.

 

19.7.        
In addition to any other remedies available to Landlord at law or in equity and under this Lease, Landlord may continue
this Lease in effect after Tenant’s Default or abandonment and recover Rent as it becomes due. In addition, Landlord shall
not be liable in any way whatsoever for its failure or refusal to relet the Premises. For purposes of this Section, the following
acts by Landlord will not constitute the termination of Tenant’s right to possession of the Premises: Acts of maintenance
or preservation or efforts to relet the Premises, including alterations, remodeling, redecorating, repairs, replacements or painting
as Landlord shall consider advisable for the purpose of reletting the Premises or any part thereof; or the appointment of a receiver
upon the initiative of Landlord to protect Landlord’s interest under this Lease or in the Premises.

 

19.8.        
Notwithstanding the foregoing, in the event of a Default by Tenant, Landlord may elect at any time to terminate this Lease
and to recover damages to which Landlord is entitled.

 

19.9.        
If Landlord does not elect to terminate this Lease as provided in this Section 19, then Landlord may, from time to
time, recover all Rent as it becomes due under this Lease. At any time thereafter, Landlord may elect to terminate this Lease and
to recover damages to which Landlord is entitled.

 

19.10.      
All of Landlord’s rights, options and remedies hereunder shall be construed and held to be nonexclusive and cumulative.
Notwithstanding any provision of this Lease to the contrary, in no event shall Landlord be required to mitigate its damages with
respect to any default by Tenant, except as required by Applicable Laws. Any such obligation imposed by Applicable Laws upon Landlord
to relet the Premises after any termination of this Lease shall be subject to the reasonable requirements of Landlord to lease
to high quality tenants on such terms as Landlord may from time to time deem appropriate in its discretion. Landlord shall not
be obligated to relet the Premises to any party (a) unacceptable to a Lender, (b) that requires Landlord to make improvements to
or re-demise the Premises, (c) that desires to change the Permitted Use, (e) that desires to lease the Premises for more or less
than the remaining Term or (e) to whom Landlord or an affiliate of Landlord may desire to lease other available space in the Project
or at another property owned by Landlord or an affiliate of Landlord.

 

19.11.     
To the extent permitted by Applicable Laws, Tenant waives any and all rights of redemption granted by or under any present
or future Applicable Laws if Tenant is evicted or dispossessed for any cause, or if Landlord obtains possession of the Premises
due to Tenant’s default hereunder or otherwise.

 

    22

     

    

 

19.12.      
Landlord shall not be in default or liable for damages under this Lease unless Landlord fails to perform obligations required
of Landlord within a reasonable time. In no event shall Tenant have the right to terminate or cancel this Lease or to withhold
or abate rent or to set off any Claims against Rent as a result of any default or breach by Landlord of any of its covenants, obligations,
representations, warranties or promises hereunder, except as may otherwise be expressly set forth in this Lease. Notwithstanding
anything to the contrary set forth in this Lease, in the event that (a) a Notice of Demand is filed with the AAA in connection
with a Disbursement Claim (as such terms are defined in the Development Agreement), (b) the Final Arbitration Decision (as defined
in the Development Agreement) requires Landlord to pay any Required Arbitration Construction Payments or any other monetary damages
to Tenant, and (c) Landlord fails to pay such monetary damages to Tenant within thirty (30) days of the issuance of such decision,
then Tenant shall be entitled to offset any payments of Rent due under this Lease required to be made by Tenant under from Tenant
under this Lease until such time as Tenant has been reimbursed in full for the unpaid amount of such award. To the extent Tenant
funds any Required Arbitration Construction Payments (as defined in the Development Agreement), then, in addition to the foregoing,
Base Rent shall be adjusted as provided for in Section 5.2.3, above.

 

19.13.      
In the event of any default by Landlord, Tenant shall give notice by registered or certified mail to any (a) beneficiary
of a deed of trust or (b) mortgagee under a mortgage covering the Premises or any portion thereof and to any landlord of any lease
of land upon or within which the Premises are located, and shall offer such beneficiary, mortgagee or landlord a reasonable opportunity
to cure the default, including time to obtain possession of the Premises by power of sale or a judicial action if such should prove
necessary to effect a cure; provided that Landlord shall furnish to Tenant in writing, upon written request by Tenant, the names
and addresses of all such persons who are to receive such notices.

 

20.          
Damage or Destruction.

 

20.1.        
Tenant’s Obligation to Rebuild.  If the Premises are damaged or destroyed, Tenant shall immediately provide
notice thereof to Landlord, and shall promptly thereafter deliver to Landlord Tenant’s good faith estimate of the time it
will take to repair and rebuild the Premises (the “Estimated Time For Repair”). Subject to the other provisions
of this Section 20, Tenant shall promptly and diligently repair and rebuild the Premises in accordance Section 20 unless
Landlord or Tenant terminates this Lease in accordance with Section 20.2.

 

20.2.        
Termination. 

 

20.2.1.     
Landlord’s Right to Terminate.

 

20.2.1.1.
Landlord shall have the right to terminate this Lease following damage to or destruction
of all or a substantial portion of the Premises if any of the following occurs (each, a “Termination
Condition”): (i) insurance proceeds, together with additional amounts Tenant agrees
to contribute under this Section 20, are not confirmed to be available to Landlord, within 90 days following the date of
damage, to pay 100% of the cost to fully repair the damaged Premises, excluding the deductible for which Tenant shall also be responsible
for paying as an Operating Expense; (ii) based upon the Estimated Time For Repair, the Premises cannot, with reasonable diligence,
be fully repaired by Tenant within eighteen (18) months after the date of the damage or destruction; (iii) the Premises
cannot be safely repaired because of the presence of hazardous factors, including, but not limited to, earthquake faults, chemical
waste and other similar dangers; (iv) subject to the terms and conditions of Section 20.2.1.1. hereof,
all or a substantial portion of the Premises are destroyed or damaged during the last 24 months of the Term; or (v) Tenant
is in Default at the time of such damage or destruction past any period of notice and cure as elsewhere provided in this Lease.
For purposes of this Section 20.2, a “substantial portion” of the Premises shall be deemed to be damaged
or destroyed if the Premises is rendered unsuitable for the continued use and occupancy of Tenant’s business substantially
in the same manner conducted prior to the event causing the damage or destruction. 

 

20.2.1.2.
If all or a substantial portion of the Premises are destroyed or damaged within the last
twenty-four (24) months of the initial Term, or within the last twenty-four (24) months of the first Extension Period
under this Lease, and Landlord desires to terminate this Lease under Section 20.2.1.1. hereof, Landlord shall
deliver a Termination Notice to Tenant pursuant to Section 20.2.3 below and Tenant shall have a period of thirty (30) days
after receipt of the Termination Notice (“Tenant’s Early Option
Period”) to exercise its option to extend the initial Term or the first Extension Period,
as applicable, by providing Landlord with written notice of Tenant’s exercise of its option prior to the expiration of Tenant’s
Early Option Period. If Tenant exercises its option rights under the immediately preceding sentence, the Termination Notice
shall be deemed rescinded and Tenant shall proceed to repair and rebuild the Premises in accordance with the other provisions of
this Section 20. If Tenant fails to deliver such written notice to Landlord prior to the end of Tenant’s Early Option
Period, then Tenant shall be deemed to have waived its option to extend the Term, and the last day of Tenant’s Early Option
Period shall be deemed to be the date of the occurrence of the Termination Condition under Section 20.2.1.1.

 

    23

     

    

 

20.2.2.     
Tenant’s Right to Terminate. Tenant shall have the right to terminate
this Lease following damage to or destruction of all or a substantial portion of the Premises if the Premises are destroyed or
damaged during the last twelve (12) months of the Term, which termination shall be deemed to constitute a Termination Condition.

 

20.2.3.     
Exercise of Termination Right. If a party elects to terminate this Lease and
has the right to so terminate, such party will give the other party written notice of its election to terminate (“Termination
Notice”) within thirty (30) days after the occurrence of the applicable Termination
Condition, and this Lease will terminate fifteen (15) days after the receiving party’s receipt of such Termination
Notice, except in the case of a termination by Landlord under Section 20.2.1.1, in which case this Lease will
terminate fifteen (15) days after expiration of the Tenant Early Option Period if Tenant timely fails to exercise timely
Tenant’s option to extend the Term. If this Lease is terminated pursuant to Section 20.2, Landlord shall,
subject to the rights of its lender(s), be entitled to receive and retain all the insurance proceeds resulting from such damage,
including rental loss insurance, except for those proceeds payable under policies obtained by Tenant which specifically insure
Tenant’s personal property, trade fixtures and machinery. 

 

20.3.        
Tenant’s Obligation to Repair. If Tenant is required to repair or rebuild
any damage or destruction of the Premises under Section 20.1, then Tenant shall (a) submit its plans to repair
such damage and reconstruct the Premises to Landlord for review and approval, which approval shall not be unreasonably withheld;
(b) diligently repair and rebuild the Premises in the same or better condition and with the same or better quality of materials
as the condition of the Premises as of the Commencement Date, and in a manner that is consistent with the plans and specifications
approved by Landlord; (c) obtain all permits and governmental approvals necessary to repair or reconstruct the Premises (which
permits shall not contain any conditions that are materially more restrictive than the permits in existence on the date hereof);
(d) cause all work to be performed only by qualified contractors that are reasonably approved by Landlord; (e) allow
Landlord and its consultants and agents to enter the Premises at all reasonable times to inspect the Premises and Tenant’s
ongoing work and cooperate reasonably in good faith with their effort to ensure that the work is proceeding in a manner that is
consistent with this Lease; (f) comply with all applicable laws and permits in connection with the performance of such work;
(g) timely pay all of its consultants, suppliers and other contractors in connection with the performance of such work; (h) notify
Landlord if Tenant receives any notice of any default or any violation of any applicable law or any permit or similar notice in
connection with such work; (i) deliver as-built plans for the Premises within thirty (30) days after the completion of
such repair and restoration; (j) ensure that Landlord has fee simple title to the Premises during such work without any claim
by any contractor or other party; (k) maintain such insurance as Landlord may reasonably require (including insurance in the
nature of builders’ risk insurance) and (l) comply with such other conditions as Landlord may reasonably require. In
addition, Tenant shall, at its expense, replace or fully repair all of Tenant’s personal property and any alterations installed
by Tenant existing at the time of such damage or destruction. To the fullest extent permitted by law, Tenant shall indemnify, protect,
defend and hold Landlord (and its employees and agents) harmless from and against any and all claims, costs, expenses, suits, judgments,
actions, investigations, proceedings and liabilities arising out of or in connection with Tenant’s obligations under this Section
20, including, without limitation, any acts, omissions or negligence in the making or performance of any such repairs or replacements.
In the event Tenant does not repair and rebuild the Premises pursuant to this Section 20, Tenant shall be in breach,
and Landlord shall have the right to retain all casualty insurance proceeds and condemnation proceeds.

 

20.4.        
Application of Insurance Proceeds for Repair and Rebuilding. Landlord
shall cause the insurance proceeds (the “Insurance Proceeds”)
on account of such damage or destruction to be held by Landlord and disbursed as follows:

 

    24

     

    

 

20.4.1.     
Minor Restorations. If (i) the estimated cost of restoration is less than One
Million Dollars ($1,000,000.00), (ii) prior to commencement of restoration, no Default or event which, with the passage of time,
would give rise to a Default shall exist and no mechanics’ or materialmen’s liens shall have been filed and remain
undischarged, (iii) the architects, contracts, contractors, plans and specifications for the restoration shall have been approved
by Landlord (which approval shall not be unreasonably withheld or delayed), (iv) Landlord shall be provided with reasonable assurance
against mechanics’ liens, accrued or incurred, as Landlord or its lenders may reasonably require and such other documents
and instruments as Landlord or its lenders may reasonably require, and (v) Tenant shall have procured acceptable performance and
payment bonds reasonably acceptable to Landlord in an amount and form, and from a surety, reasonably acceptable to Landlord, and
naming Landlord as an additional obligee; then Landlord shall make available that portion of the Insurance Proceeds to Tenant for
application to pay the costs of restoration incurred by Tenant and Tenant shall promptly complete such restoration.

 

20.4.2.     
Other Than Minor Restorations. If the estimated cost of restoration is equal
to or exceeds One Million Dollars ($1,000,000.00), and if Tenant provides evidence satisfactory to Landlord that sufficient funds
are available to restore the Premises, Landlord shall make disbursements from the available Insurance Proceeds from time to time
in an amount not exceeding the cost of the work completed since the date covered by the last disbursement, upon receipt of (i) satisfactory
evidence, including architect’s certificates, of the stage of completion, of the estimated cost of completion and of performance
of the work to date in a good and workmanlike manner in accordance with the contracts, plans and specifications, (ii) reasonable
assurance against mechanics’ or materialmen’s liens, accrued or incurred, as Landlord or its lenders may reasonably
require, (iii) contractors’ and subcontractors’ sworn statements, (iv) a satisfactory bring-to-date of title
insurance, (v) performance and payment bonds reasonably acceptable to Landlord in an amount and form, and from a surety, reasonably
acceptable to Landlord, and naming Landlord as an additional obligee, (vi) such other documents and instruments as Landlord
or its lenders may reasonably require, and (vii) other evidence of cost and payment so that Landlord can verify that the amounts
disbursed from time to time are represented by work that is completed, in place and free and clear of mechanics’ lien claims.

 

20.4.3.     
Requests for Disbursements. Requests for disbursement shall be made no more
frequently than monthly and shall be accompanied by a certificate of Tenant describing in detail the work for which payment is
requested, stating the cost incurred in connection therewith and stating that Tenant has not previously received payment for such
work; the certificate to be delivered by Tenant upon completion of the work shall, in addition, state that the work has been completed
and complies with the applicable requirements of this Lease. Landlord may retain 10% of each requisition until the restoration
is fully completed. In addition, Landlord may withhold from amounts otherwise to be paid to Tenant, any amount that is necessary
in Landlord’s reasonable judgment to protect Landlord from any potential loss due to work that is improperly performed or
claims by Tenant’s contractors and consultants.

 

20.4.4.     
Costs in Excess of Insurance Proceeds. In addition, prior to commencement of
restoration and at any time during restoration, if the estimated cost of restoration, as determined by the evaluation of an independent
engineer acceptable to Landlord and Tenant, exceeds the amount of the Insurance Proceeds, Tenant will provide evidence satisfactory
to Landlord that the amount of such excess will be available to restore the Premises. Any Insurance Proceeds remaining upon completion
of restoration shall be refunded to Tenant up to the amount of Tenant’s payments pursuant to the immediately preceding sentence.
If no such refund is required, any sum of Insurance Proceeds remaining upon completion of restoration shall be paid to Landlord.
In the event Landlord and Tenant cannot agree on an independent engineer, an independent engineer designated by Tenant and an independent
engineer designated by Landlord shall within five (5) business days select an independent engineer licensed to practice in Pennsylvania
who shall resolve such dispute within ten (10) business days after being retained by Landlord. All fees, costs and expenses
of such third engineer so selected shall be shared equally by Landlord and Tenant.

 

20.5.        
Abatement of Rent. In the event of repair, reconstruction and restoration
as provided in this Section, all Rent to be paid by Tenant under this Lease shall be abated proportionately based on the extent
to which Tenant’s use of the Premises is impaired during the period of such repair, reconstruction or restoration, unless
Landlord provides Tenant with other space during the period of repair, reconstruction and restoration that, in Tenant’s reasonable
opinion, is suitable for the temporary conduct of the Tenant’s business in accordance with Applicable Law; provided,
however, that the amount of such abatement shall be reduced by the amount of Rent that is received by Tenant as part of the business
interruption or loss of rental income with respect to the Premises from the proceeds of business interruption or loss of rental
income insurance. Tenant shall not otherwise be entitled to any compensation or damages from
Landlord for loss of the use of the Premises, damage to Tenant’s personal property or any inconvenience occasioned by such
damage, repair or restoration.  

 

    25

     

    

 

20.6.        
Replacement Cost. The determination in good faith by Landlord of the estimated
cost of repair of any damage, of the replacement cost, or of the time period required for repair shall be conclusive for purposes
of this Section 20.

 

20.7.        
This Section 20 sets forth the terms and conditions upon which this Lease may terminate in the event of any damage
or destruction. Accordingly, the parties hereby waive the provisions of any Applicable Laws (and any successor statutes) permitting
the parties to terminate this Lease as a result of any damage or destruction.

 

21.          
Eminent Domain.

 

21.1.        
In the event (a) the whole of the Premises or (b) such part thereof as shall substantially interfere with Tenant’s
use and occupancy of the Premises for the Permitted Use shall be taken for any public or quasi-public purpose by any lawful power
or authority by exercise of the right of appropriation, condemnation or eminent domain, or sold to prevent such taking, Tenant
or Landlord may terminate this Lease effective as of the date possession is required to be surrendered to such authority, except
with regard to (y) items occurring prior to the taking and (z) provisions of this Lease that, by their express terms, survive the
expiration or earlier termination hereof.

 

21.2.         
In the event of a partial taking of the Premises for any public or quasi-public purpose by any lawful power or authority
by exercise of right of appropriation, condemnation, or eminent domain, or sold to prevent such taking, then, without regard to
whether any portion of the Premises occupied by Tenant was so taken, Landlord may elect to terminate this Lease (except with regard
to (a) items occurring prior to the taking and (b) provisions of this Lease that, by their express terms, survive the expiration
or earlier termination hereof) as of such taking if such taking is, in Landlord’s sole opinion, of a material nature such
as to make it uneconomical to continue use of the unappropriated portion for the Permitted Use.

 

21.3.        
Tenant shall be entitled to any award that is specifically awarded as compensation for (a) the taking of Tenant’s
personal property or trade fixtures that were purchased or installed at Tenant’s expense, including without limitation, any
crops or inventory at the Property and (b) the costs of Tenant moving to a new location. Except as set forth in the previous sentence,
any award for such taking shall be the property of Landlord.

 

21.4.        
If, upon any taking of the nature described in this Section, this Lease continues in effect, then Landlord shall promptly
proceed to restore the Premises to substantially their same condition prior to such partial taking. To the extent such restoration
is infeasible, as determined by Landlord in its sole and absolute discretion, the Rent shall be decreased proportionately to reflect
the loss of any portion of the Premises no longer available to Tenant.

 

21.5.        
This Section 21 sets forth the terms and conditions upon which this Lease may terminate in the event of any damage
or destruction. Accordingly, the parties hereby waive the provisions of any Applicable Laws (and any successor statutes) permitting
the parties to terminate this Lease as a result of any damage or destruction.

 

22.           
Surrender. At least thirty (30) days prior to Tenant’s surrender of possession of any part of the Premises,
Tenant shall provide Landlord with a facility decommissioning and Hazardous Materials closure plan for the Premises (“Exit
Survey”) prepared by an independent third party state-certified professional with appropriate expertise, which Exit Survey
must be reasonably acceptable to Landlord. In addition, at least ten (10) days prior to Tenant’s surrender of possession
of any part of the Premises, Tenant shall (a) provide Landlord with written evidence of all appropriate governmental releases obtained
by Tenant in accordance with Applicable Laws, including laws pertaining to the surrender of the Premises, and (b) conduct a site
inspection with Landlord. In addition, Tenant agrees to remain responsible after the surrender of the Premises for the remediation
of any recognized environmental conditions set forth in the Exit Survey and comply with any recommendations set forth in the Exit
Survey. Tenant’s obligations under this Section shall survive the expiration or earlier termination of the Lease. The provisions
of this Section shall survive the termination or expiration of this Lease, and no surrender of possession of any part of the Premises
shall release Tenant from any of its obligations hereunder, unless such surrender is accepted in writing by Landlord.

 

    26

     

    

 

23.          
Bankruptcy. In the event a debtor, trustee or debtor in possession under the Bankruptcy Code, or another person with
similar rights, duties and powers under any other Applicable Laws, proposes to cure any default under this Lease or to assume or
assign this Lease and is obliged to provide adequate assurance to Landlord that (a) a default shall be cured, (b) Landlord shall
be compensated for its damages arising from any breach of this Lease and (c) future performance of Tenant’s obligations under
this Lease shall occur, then such adequate assurances shall include any or all of the following, as designated by Landlord in its
sole and absolute discretion: (w) those acts specified in the Bankruptcy Code or other Applicable Laws as included within the meaning
of “adequate assurance,” even if this Lease does not concern a facility described in such Applicable Laws; (x) a prompt
cash payment to compensate Landlord for any monetary defaults or actual damages arising directly from a breach of this Lease; (y)
a cash deposit in an amount at least equal to the then-current amount of the Security Deposit; or (z) the assumption or assignment
of all of Tenant’s interest and obligations under this Lease.

 

24.          
Brokers. Each of Landlord and Tenant represents and warrants that it has had no dealings with any real estate broker
or agent in connection with the negotiation of this Lease and that it knows of no real estate broker or agent that is or might
be entitled to a commission in connection with this Lease. Tenant agrees to indemnify, save, defend (at Landlord’s option
and with counsel reasonably acceptable to Landlord) and hold the Landlord Indemnitees harmless from any and all cost or liability
for compensation claimed by any broker or agent employed or engaged by Tenant or claiming to have been employed or engaged by Tenant.
Landlord agrees to indemnify, save, defend (at Tenant’s option and with counsel reasonably acceptable to Tenant) and hold
the Tenant and its affiliates, lenders, employees, agents and contractors harmless from any and all cost or liability for compensation
claimed by any broker or agent employed or engaged by Landlord or claiming to have been employed or engaged by Landlord. The provisions
of this Section shall survive the expiration or termination of this Lease.

 

25.          
Definition of Landlord. With regard to obligations imposed upon Landlord pursuant to this Lease, the term “Landlord,”
as used in this Lease, shall refer only to Landlord or Landlord’s then-current successor-in-interest. In the event of any
transfer, assignment or conveyance of Landlord’s interest in this Lease or in Landlord’s fee title to or leasehold
interest in the Property, as applicable, Landlord herein named (and in case of any subsequent transfers or conveyances, the subsequent
Landlord) shall be automatically freed and relieved, from and after the date of such transfer, assignment or conveyance, from all
liability for the performance of any covenants or obligations contained in this Lease thereafter to be performed by Landlord and,
without further agreement, the transferee, assignee or conveyee of Landlord’s in this Lease or in Landlord’s fee title
to or leasehold interest in the Property, as applicable, shall be deemed to have assumed and agreed to observe and perform any
and all covenants and obligations of Landlord hereunder during the tenure of its interest in the Lease or the Property. Landlord
or any subsequent Landlord may transfer its interest in the Premises or this Lease without Tenant’s consent.

 

26.          
Limitation of Landlord’s Liability. If Landlord is in default under this Lease and, as a consequence, Tenant
recovers a monetary judgment against Landlord, the judgment shall be satisfied only out of (a) the proceeds of sale received on
execution of the judgment and levy against the right, title and interest of Landlord in the Premises, (b) rent or other income
from such real property receivable by Landlord or (c) the consideration received by Landlord from the sale, financing, refinancing
or other disposition of all or any part of Landlord’s right, title or interest in the Premises. Neither Landlord nor any
of its affiliates, nor any of their respective partners, shareholders, directors, officers, employees, members or agents shall
be personally liable for Landlord’s obligations or any deficiency under this Lease. No partner, shareholder, director, officer,
employee, member or agent of Landlord or any of its affiliates shall be sued or named as a party in any suit or action. No partner,
shareholder, director, officer, employee, member or agent of Landlord or any of its affiliates shall be required to answer or otherwise
plead to any service of process, and no judgment shall be taken or writ of execution levied against any partner, shareholder, director,
officer, employee, member or agent of Landlord or any of its affiliates. Each of the covenants and agreements of this Section
26 shall be applicable to any covenant or agreement either expressly contained in this Lease or imposed by Applicable Laws
and shall survive the expiration or earlier termination of this Lease.

 

    27

     

    

 

 

27.               
Control by Landlord. Landlord reserves full control over the Premises to the extent not inconsistent with Tenant’s
enjoyment of the same as provided by this Lease; provided, however, that such rights shall be exercised in a way that does
not materially adversely affect Tenant’s beneficial use and occupancy of the Premises, including the Permitted Use and Tenant’s
access to the Premises. Tenant shall, at Landlord’s request, promptly execute such further documents as may be reasonably
appropriate to assist Landlord in the performance of its obligations hereunder; provided that Tenant need not execute any
document that creates additional liability for Tenant or that deprives Tenant of the quiet enjoyment and use of the Premises as
provided for in this Lease. Landlord may, upon not less than twenty-four (24) hours’ prior notice (which may be oral or by
email to the office manager or other Tenant-designated individual at the Premises; but provided that no time restrictions
shall apply or advance notice be required if an emergency necessitates immediate entry), enter the Premises to (u) inspect the
same and to determine whether Tenant is in compliance with its obligations hereunder, (v) supply any service Landlord is required
to provide hereunder, (w) post notices of nonresponsibility and (x) show the Premises to prospective tenants during the final year
of the Term and current and prospective purchasers and lenders at any time (in all situations provided that Landlord’s personnel
are accompanied by Tenants’ authorized personnel). In no event shall Tenant’s Rent abate as a result of Landlord’s
activities pursuant to this Section 27; provided, however, that all such activities shall be conducted in such a
manner so as to cause as little interference to Tenant as is reasonably possible, and any access by Landlord shall be in accordance
with Applicable Law and shall be subject to any security procedures established by Tenant from time to time. If an emergency necessitates
immediate access to the Premises, Landlord may use whatever force is necessary to enter the Premises, and any such entry to the
Premises shall not constitute a forcible or unlawful entry to the Premises, a detainer of the Premises, or an eviction of Tenant
from the Premises or any portion thereof.

 

28.                
Joint and Several Obligations. If more than one person or entity executes this Lease as Tenant, then (a) each of
them is jointly and severally liable for the keeping, observing and performing of all of the terms, covenants, conditions, provisions
and agreements of this Lease to be kept, observed or performed by Tenant, and such terms, covenants, conditions, provisions and
agreements shall be binding with the same force and effect upon each and all of the persons executing this Lease as Tenant; and
(b) the term “Tenant,” as used in this Lease, shall mean and include each
of them, jointly and severally. The act of, notice from/to, refund to, or signature of any one or more of them with respect to
the tenancy under this Lease, including any renewal, extension, expiration, termination or modification of this Lease, shall be
binding upon each and all of the persons executing this Lease as Tenant with the same force and effect as if each and all of them
had so acted, so given or received such notice or refund, or so signed.

 

29.               
Representations. Each of Tenant and Landlord guarantees, warrants and represents that (a) such party is duly incorporated
or otherwise established or formed and validly existing under the laws of its state of incorporation, establishment or formation,
(b) such party is duly qualified to do business in the state in which the Property is located, (c) such party has full corporate,
partnership, trust, association or other appropriate power and authority to enter into this Lease and to perform its obligations
hereunder, (d) each person (and all of the persons if more than one signs) signing this Lease on behalf of such party is duly and
validly authorized to do so and (e) neither (i) the execution, delivery or performance of this Lease nor (ii) the consummation
of the transactions contemplated hereby will violate or conflict with any provision of documents or instruments under which such
party is constituted or to which such party is a party. In addition, Tenant guarantees, warrants and represents that none of (x)
it, (y) its affiliates or partners nor (z) to the best of its knowledge, its members, shareholders or other equity owners or any
of their respective employees, officers, directors, representatives or agents is a person or entity with whom U.S. persons or entities
are restricted from doing business under regulations of the Office of Foreign Asset Control (“OFAC”)
of the Department of the Treasury (including those named on OFAC’s Specially Designated and Blocked Persons List) or under
any statute, executive order (including the September 24, 2001, Executive Order Blocking Property and Prohibiting Transactions
with Persons Who Commit, Threaten to Commit, or Support Terrorism) or other similar governmental action.

 

30.                
Confidentiality. Each of Landlord and Tenant shall keep the terms and conditions of this Lease confidential and shall
not (a) disclose to any third party any terms or conditions of this Lease or any other Lease-related document (including subleases,
assignments, work letters, construction contracts, letters of credit, subordination agreements, non-disturbance agreements, brokerage
agreements or estoppels) or (b) provide to any third party an original or copy of this Lease (or any Lease-related document). Notwithstanding
the foregoing, confidential information under this Section may be released by Landlord or Tenant under the following circumstances:
(x) if required by Applicable Laws or in any judicial proceeding; provided that the releasing party has given the other
party reasonable notice of such requirement, if feasible, (y) to a party’s (and its affiliate’s) employees, partners,
attorneys, investors, lenders, accountants, brokers, prospective purchasers, and other bona fide consultants or advisers; provided
such third parties agree to be bound by this Section or (z) to bona fide prospective assignees or subtenants of this Lease; provided
they agree in writing to be bound by this Section.

 

    28

     

    

 

31.                
Notices. Except as otherwise stated in this Lease, any notice, consent, demand, invoice, statement or other communication
required or permitted to be given hereunder shall be in writing and shall be given by (a) personal delivery, (b) overnight delivery
with a reputable international overnight delivery service, such as FedEx, or (c) facsimile or email transmission, so long as such
transmission is followed within one (1) business day by delivery utilizing one of the methods described in Subsection 31(a)
or (b). Any such notice, consent, demand, invoice, statement or other communication shall be deemed delivered (x) upon receipt,
if given in accordance with Subsection 31(a); (y) one (1) business day after deposit with a reputable international overnight
delivery service, if given if given in accordance with Subsection 31(b); or (z) upon transmission, if given in accordance
with Subsection 31(c). Except as otherwise stated in this Lease, any notice, consent, demand, invoice, statement or other
communication required or permitted to be given pursuant to this Lease shall be addressed to Tenant at the Premises, or to Landlord
or Tenant at the addresses shown in Section 2. Either party may, by notice to the other given pursuant to this Section,
specify additional or different addresses for notice purposes.

 

32.                
Release; Put Right. 

 

32.1.                      
If at any time during the first four (4) years of the Lease Term the Tenant is required or decides to divest, relinquish,
sell, assign or otherwise directly or indirectly transfer the government approvals/licenses required to operate its business pursuant
to the Permitted Use (the “License Transfer”), the Landlord agrees to release
Tenant and all Guarantors from any obligations with respect to this Lease and the Property (including, without limitation, all
guarantees executed in connection with the Lease), and such new license owner/transferee (the “License Transferee”)
will replace Tenant and all Guarantors as the sole guarantor under this Lease. Tenant will deliver written notice of any License
Transfer (the “Transfer Notice”) at least thirty (30) days prior to the closing
of the License Transfer, which notice will provide the identity of the License Transferee. Within fifteen (15) days following the
Transfer Notice, Landlord may elect to put the Property (as such term is defined in the Purchase Agreement) to Tenant (or its designee)
for a purchase price equal to the then-current fair market value of the Property (as determined by a nationally recognized M.A.I.
appraiser reasonably acceptable to both Landlord and Tenant), which in no event shall be less than the Minimum Price (as defined
below). As used herein, the “Minimum Price” shall mean and equal the remainder
of (A) the quotient of (i) the total Base Rent payable during the calendar year in which the License Transfer notice is delivered,
divided by (ii) Nine and Seventy-Five One Hundredths Percent (9.75%); LESS (B) any unfunded Construction Contribution Amount (as
defined in the Development Agreement). 

 

32.2.                      
Landlord and Tenant agree to cooperate and coordinate in connection with (a) such release, including the execution of releases
for the Tenant and all Guarantors, and, (b) if the Landlord exercises its put right, such sale, including execution of a Purchase
and Sale Agreement on commercially reasonable terms (the “PSA”) and all documents
required under the PSA (and otherwise required to effectuate and close the transaction contemplated under the PSA), and commercially
reasonable efforts to cause and facilitate the closing to occur pursuant to the PSA. The releases described above and any closing
under the PSA shall occur simultaneously with the closing of the License Transfer.

 

32.3.                      
Upon the earlier to occur of (a) the effective date of the License Transfer or (b) the expiration of the four-year period
referenced in Section 32.1 without the delivery of a Transfer Notice, then the provisions of this Section 32 shall
terminate. 

 

33.               
Guaranties. In the event that any entity becomes an affiliate of Tenant after the Execution Date which entity conducts
business in cannabis industry (each, a “New Guarantor”), Tenant shall promptly
cause such New Guarantor to execute a Guaranty in the form attached hereto as Exhibit D and deliver such executed Guaranty
to Landlord. Any failure by Tenant to provide such Guaranty within thirty (30) days following the formation of such New Guarantor
shall be deemed a material default under this Lease. The obligations of each Guarantor shall be joint and several and Tenant shall
cause each Guarantor to execute and deliver such further documentation as may be reasonably required to confirm such Guarantor’s
full and unconditional guaranty of Tenant’s obligations under this Lease. For purposes of this Section 33, an “entity
affiliated with Tenant” shall mean any entity (a) that is a subsidiary of PharmaCann LLC, an Illinois limited liability company
(“PharmaCann LLC”), or (b) that PharmaCann LLC holds an equity interest in,
directly or indirectly; provided that, Landlord shall be entitled to seek recourse only against the interests of Tenant or PharmaCann
LLC in any such New Guarantor, and the form of Guaranty shall be conformed accordingly for any such New Guarantor. Notwithstanding
anything in this Lease or the applicable Guaranty to the contrary, Landlord agrees to execute a commercially reasonable form of
subordination agreement that subordinates Landlord’s rights under a Guaranty to an institutional lender’s or third
party financing source’s rights with respect to a contemplated financing by the applicable Guarantor, provided that the following
conditions are satisfied: 1) the subordination of the Guaranty is a requirement of the lender or other third party financing source
to provide the financing to the Guarantor; and 2) at the time of Landlord’s execution of such subordination agreement, (a)
neither Tenant nor any Guarantor is then in default of its obligations under the Lease or any Guaranty; and (b) neither Tenant
nor any Guarantor has defaulted on its obligations under either the Lease or any Guaranty more than two (2) times during the immediately
prior six (6) month period.

 

    29

     

    

 

34.               
Miscellaneous.

 

34.1.          
To induce Landlord to enter into this Lease, Tenant agrees that it shall, (a) within sixty (60) days after the end of Tenant’s
financial year, furnish Landlord with a certified copy of Tenant’s audited year-end unconsolidated financial statements for
the previous year and shall cause each Guarantor to furnish Landlord with a certified copy of their respective audited year-end
unconsolidated financial statements for the previous year; (b) as soon as produced after the end of each of the Tenant’s
fiscal first, second and third quarters, and in any event within a reasonable time period before Landlord is required to make any
filings to the SEC requiring such information, furnish Landlord with a certified copy of Tenant’s unaudited financial statements
for the quarter; and (c) provide copies to Landlord of any budgets, forecasts and investor materials. Tenant represents and warrants
that all financial statements, records and information furnished by Tenant to Landlord in connection with this Lease are true,
correct and complete in all respects and that all financial statements, records and information furnished by each Guarantor to
Landlord in connection with this Lease are true, correct and complete in all respects. The provisions of this Section shall not
apply to Tenant or any Guarantor (as applicable) during any time period that Tenant or such Guarantor is a corporation whose shares
are traded on any nationally recognized stock exchange. In addition, Tenant and each Guarantor agrees to timely provide financial
statements to the Landlord to the extent that such financial statements are required to be included in filings made by Landlord
or Landlord’s affiliates with the U.S. Securities and Exchange Commission (the “SEC”),
which may include consolidated balance sheets, statements of operations, statements of cash flows and statements of stockholders
equity, and related footnotes, prepared in accordance with U.S. generally accepted accounting principles or International Financial
Reporting Standards (provided that such method of accounting is acceptable to the SEC and satisfies the Landlord’s and its
affiliates’ obligations with respect to required filings with the SEC) and reviewed (in the case of quarterly financial statements)
or audited (in the case of annual financial statements) by Tenant’s or Guarantor’s independent auditors (within the
requirements of Regulation S-X under the rules and regulations of the SEC, as interpreted by the staff of the SEC), as reasonably
requested by the Landlord. Notwithstanding the foregoing, in the event that Tenant’s financials are consolidated with Tenant’s
parent company, PharmaCann LLC, Tenant may deliver the financial statements of its parent company in accordance with this Section
in satisfaction of Tenant’s requirements hereunder. 

 

34.2.          
The terms of this Lease, the Development Agreement and the Multi-Party PA Agreement are intended by the parties as a final,
complete and exclusive expression of their agreement with respect to the terms that are included herein, and may not be contradicted
or supplemented by evidence of any other prior or contemporaneous agreement.

 

34.3.          
Either party may record a memorandum of this Lease.

 

34.4.          
Landlord and Tenant have each participated in the drafting and negotiation of this Lease, and the language in all parts
of this Lease shall be in all cases construed as a whole according to its fair meaning and not strictly for or against either Landlord
or Tenant.

 

34.5.          
Except as otherwise expressly set forth in this Lease, each party shall pay its own costs and expenses incurred in connection
with this Lease and such party’s performance under this Lease; provided that, if either party commences an action,
proceeding, demand, claim, action, cause of action or suit against the other party arising out of or in connection with this Lease,
then the substantially prevailing party shall be reimbursed by the other party for all reasonable costs and expenses, including
reasonable attorneys’ fees and expenses, incurred by the substantially prevailing party in such action, proceeding, demand,
claim, action, cause of action or suit, and in any appeal in connection therewith (regardless of whether the applicable action,
proceeding, demand, claim, action, cause of action, suit or appeal is voluntarily withdrawn or dismissed).

 

    30

     

    

 

34.6.          
Time is of the essence with respect to the performance of every provision of this Lease.

 

34.7.          
Each provision of this Lease performable by Tenant shall be deemed both a covenant and a condition.

 

34.8.          
Notwithstanding anything to the contrary contained in this Lease, Tenant’s obligations under this Lease are independent
and shall not be conditioned upon performance by Landlord.

 

34.9.          
Whenever consent or approval of either party is required, that party shall not unreasonably withhold, condition or delay
such consent or approval, except as may be expressly set forth to the contrary.

 

34.10.       
Any provision of this Lease that shall prove to be invalid, void or illegal shall in no way affect, impair or invalidate
any other provision hereof, and all other provisions of this Lease shall remain in full force and effect and shall be interpreted
as if the invalid, void or illegal provision did not exist.

 

34.11.       
Each of the covenants, conditions and agreements herein contained shall inure to the benefit of and shall apply to and be
binding upon the parties hereto and their respective heirs; legatees; devisees; executors; administrators; and permitted successors
and assigns. This Lease is for the sole benefit of the parties and their respective heirs, legatees, devisees, executors, administrators
and permitted successors and assigns, and nothing in this Lease shall give or be construed to give any other person or entity any
legal or equitable rights. Nothing in this Section shall in any way alter the provisions of this Lease restricting assignment or
subletting.

 

34.12.       
This Lease shall be governed by, construed and enforced in accordance with the laws of the state in which the Premises are
located, without regard to such state’s conflict of law principles.

 

34.13.       
Landlord covenants that Tenant, upon paying the Rent and performing its obligations contained in this Lease, may peacefully
and quietly have, hold and enjoy the Premises, free from any claim by Landlord or persons claiming under Landlord, but subject
to all of the terms and provisions hereof, provisions of Applicable Laws and rights of record to which this Lease is or may become
subordinate. This covenant is in lieu of any other quiet enjoyment covenant, either express or implied.

 

34.14.       
Each of Tenant and Landlord guarantees, warrants and represents to the other party that the individual or individuals signing
this Lease have the power, authority and legal capacity to sign this Lease on behalf of and to bind all entities, corporations,
partnerships, limited liability companies, joint venturers or other organizations and entities on whose behalf such individual
or individuals have signed.

 

34.15.       
This Lease may be executed in one or more counterparts, each of which, when taken together, shall constitute one and the
same document.

 

34.16.       
No provision of this Lease may be modified, amended or supplemented except by an agreement in writing signed by Landlord
and Tenant.

 

34.17.       
No waiver of any term, covenant or condition of this Lease shall be binding upon Landlord unless executed in writing by
Landlord. The waiver by Landlord of any breach or default of any term, covenant or condition contained in this Lease shall not
be deemed to be a waiver of any preceding or subsequent breach or default of such term, covenant or condition or any other term,
covenant or condition of this Lease.

 

34.18.       
To the extent permitted by Applicable Laws, the parties waive trial by jury in any action, proceeding or counterclaim brought
by the other party hereto related to matters arising out of or in any way connected with this Lease; the relationship between Landlord
and Tenant; Tenant’s use or occupancy of the Premises; or any claim of injury or damage related to this Lease or the Premises.

 

    31

     

    

 

34.19.       
This Lease shall be governed by and construed in accordance with the laws of the State of Pennsylvania, United States of
America, without regard to principles of conflicts of laws. TO THE FULLEST EXTENT PERMITTED BY LAW, EACH PARTY HEREBY UNCONDITIONALLY
AND IRREVOCABLY WAIVES ANY CLAIM TO ASSERT THAT THE LAW OF ANY OTHER JURISDICTION GOVERNS THIS LEASE. EACH PARTY IRREVOCABLY CONSENTS
TO THE JURISDICTION OF THE STATE COURTS SITUATED IN OR HAVING JURISDICTION OVER SCOTT TOWNSHIP, PENNSYLVANIA IN ANY ACTION THAT
MAY BE BROUGHT FOR THE ENFORCEMENT OF THIS LEASE (WITH THE EXPRESS AGREEMENT THAT NO ACTION MAY BE BROUGHT IN FEDERAL COURT RELATING
IN ANY WAY TO THIS LEASE).

 

34.20.       
Landlord agrees to reasonably cooperate with Tenant (at no cost to Landlord) regarding any governmental approvals or consents
required in connection with any work to be performed, constructed or installed by Tenant pursuant to this Lease, and in connection
with Tenant’s continued use of the Property in accordance with the Lease. 

 

[The remainder of this page is intentionally
left blank. Signature page follows.]

 

    32

     

    

 

IN WITNESS
WHEREOF, the parties hereto have duly executed this Lease on the day and year first above written.

 

	LANDLORD:	 
	 	 
	IIP-PA 4 LLC,	 
	a Delaware limited liability company	 
	 	 
	 	 
	By:	/s/ Brian Wolfe	 
	Name:   	Brian Wolfe	 
	Title:	Vice President, General Counsel and Secretary	 
	 	 	 
	 	 	 
	TENANT:
	 	 	 
	PHARMACANN PENN PLANT LLC,	 
	a Pennsylvania limited liability company	 
	 	 
	 	 
	By:	/s/ Brett Novey	 
	Name:	Brett Novey	 
	Title:	Authorized Signatory	 

 

    33

     

    

 

EXHIBIT A

PROPERTY

 

ALL that certain piece or parcel of land
situate in the Township of Scott, County of Lackawanna, and Commonwealth of Pennsylvania bounded and described as follows to wit:

 

BEING Lot 4 as shown on plan entitled "LOT
LINE CHANGE WITHIN SCOTT TECHNOLOGY PARK PHASE II/ LOTS- #4 AND #11 PROPOSED LOT LINES" recorded in Map Book 6A, Page 9481,
being more particularly described as follows, to-wit:

 

BEGINNING at a found 5/8" rebar on
the southwesterly right-of-way line of Life Science Drive marking a common corner of Lot 4 and Lot 3, described as per a survey
performed by Engineering Surveying Consultants & Design Inc., on November 7, 2018;

 

THENCE along said common line of the above
mentioned Lot 4 and Lot 3 South 44'58'01" West six hundred two and seventy-nine hundredths (602.79') feet to a found 5/8"
iron pin at the Intersection of a stone row;

 

THENCE along lands now or formerly of Virginia
Wetherbee (DB 487 PG 751) and John J. Wasko (DB 1553 PG 666) North 48'40'54" West eleven hundred seventy-one and five tenths
(1171.50') feet to a point, passing a set 5/8" rebar at eight hundred eighty-six and fifteen hundredths (886.15') feet;

 

THENCE along lands now or formerly of John
J. Wasko (DB 1553 PG 666) and Lisa Tizzoni (Instr.# 2006-34752) North 41'31'06" West six hundred sixty-nine and sixty-six
hundredths (669.66') feet to the corner of Lot 11 as shown on the above referenced plan;

 

THENCE along said Lot 11 and Lands now
or formerly of Baldoni Investment Group, LLC (Instr.# 2015-12077) South 48'52'06" East eleven hundred forty-one and ninety-seven
hundredths (1141.97') feet to a found 5/8" rebar on the southwesterly right of way line of Life Science Drive, passing a set
5/8" rebar at two hundred thirty-four and thirty-five hundredths (234.35') feet and a found 5/8" rebar at seven hundred
twenty-four and thirteen hundredths (724.13') feet;

 

THENCE along said right of way line South
41'01'05" West two and eighteen hundredths (2.18') feet to a point of curvature;

 

THENCE continuing along said right of way
line, along a curve to the left having a radius of seventy (70') feet and an arc length of one hundred five and twenty-seven hundredths
feet (Chord: South 01'57'02 East 95.63') feet to the point of BEGINNING.

 

CONTAINING 18.287 acres, of land being
the same, more or less. BEING ALL of Lot 4 as shown on the above referenced plan;

 

BEING PART of lands conveyed to Pharmacann
Penn Plant LLC by Scranton Lackawanna Industrial Building Company by deed dated December 10, 2018, effective December 12, 2018
recorded December 14, 2018 as Instrument No. 201820014 in the Office of the Recorder of Deeds in Lackawanna County, Pennsylvania;

 

BEING PART of PIN Number 071.04-010-004.03

 

     

     

    

 

EXHIBIT B

 

TENANT’S
PERSONAL PROPERTY

 

None.

 

     

     

    

 

EXHIBIT C

FORM OF TENANT ESTOPPEL CERTIFICATE

 

To:          [IIP LANDLORD ENTITY]

11440 West Bernardo Court, Suite
220

San Diego, California 92127

Attention: General Counsel

 

 Re:          [PREMISES ADDRESS] (the “Premises”) at Lot No. 4, Scott Technology Park, Scott Township, Pennsylvania (the “Property”)

 

The undersigned tenant (“Tenant”)
hereby certifies to you as follows:

 

1.                  
Tenant is a tenant at the Property under a lease (the “Lease”) for the Premises dated as of [_______],
20[__]. The Lease has not been cancelled, modified, assigned, extended or amended [except as follows: [_______]], and there are
no other agreements, written or oral, affecting or relating to Tenant’s lease of the Premises or any other space at the Property.
The lease term expires on [_______], 20[__].

 

2.                  
Tenant took possession of the Premises, currently consisting of [_______] square feet, on [_______], 20[__], and commenced
to pay rent on [_______], 20[__]. Tenant has full possession of the Premises, has not assigned the Lease or sublet any part of
the Premises, and does not hold the Premises under an assignment or sublease[, except as follows: [_______]].

 

3.                  
All base rent, rent escalations and additional rent under the Lease have been paid through [_______], 20[__]. There is no
prepaid rent[, except $[_______]][, and the amount of security deposit is $[_______] [in cash][OR][in the form of a letter of credit]].
Tenant currently has no right to any future rent abatement under the Lease.

 

4.                  
Base rent is currently payable in the amount of $[_______] per month.

 

5.                  
All work to be performed for Tenant under the Lease has been performed as required under the Lease and has been accepted
by Tenant[, except [_______]], and all allowances to be paid to Tenant, including allowances for tenant improvements, moving expenses
or other items, have been paid.

 

6.                  
The Lease is in full force and effect. To the best of Tenant’s knowledge, neither Landlord nor Tenant is currently
in default of its obligations under the Lease and no event has occurred that, with the giving of notice or the passage of time,
could become a default under the Lease. To the best of Tenant’s knowledge, Tenant has no claims against the landlord or offsets
or defenses against rent, and there are no disputes with the landlord. Tenant has received no notice of prior sale, transfer, assignment,
hypothecation or pledge of the Lease or of the rents payable thereunder[, except [_______]].

 

7.                  
Tenant has no rights or options to purchase the Property, except as provided in the Lease.

 

8.                  
To Tenant’s knowledge, no hazardous wastes have been generated, treated, stored or disposed of by or on behalf of
Tenant in, on or around the Premises in violation of any environmental laws.

 

9.                  
The undersigned has executed this Estoppel Certificate with the knowledge and understanding that [INSERT NAME OF LANDLORD,
PURCHASER OR LENDER, AS APPROPRIATE] or its assignee is [acquiring the Property/making a loan secured by the Property] in reliance
on this certificate and that the undersigned shall be bound by this certificate. The statements contained herein may be relied
upon by [INSERT NAME OF PURCHASER OR LENDER, AS APPROPRIATE], [LANDLORD], IIP Operating Partnership, LP, Innovative Industrial
Properties, Inc., and any [other] mortgagee of the Property and their respective successors and assigns.

 

[Signature page follows]

 

     

     

    

 

Any capitalized terms not defined herein shall
have the respective meanings given in the Lease.

 

Dated this [____] day of [_______], 20[__].

 

 

[_______],

a [_______]

 

 

	By:	 	 
	Name:   	 	 
	Title:	 	 

 

     

     

    

 

EXHIBIT D

 

FORM
OF GUARANTY OF LEASE

 

This Guaranty of Lease
(“Guaranty”) is executed effective on the ____ day of [_______], 2019, by [_______], a [_______] (“Guarantor”),
whose address for notices is [________________], in favor of IIP- PA 4 LLC, a Delaware limited liability company (“Landlord”),
whose address for notices is 11440 West Bernardo Court, Suite 220, San Diego, California 92127, Attn: General Counsel.

 

For good and valuable
consideration, the receipt and sufficiency of which are hereby acknowledged, Guarantor covenants and agrees as follows:

 

1.                  
Recitals. This Guaranty is made with reference to the following recitals of facts which constitute a material part
of this Guaranty:

 

(a)                
Landlord, as Landlord, and PharmaCann Penn Plant LLC, a Pennsylvania limited liability company, as Tenant (“Tenant”),
entered into that certain Lease dated as of [_____], 2019 (the “Lease”), with respect to the property located
at Lot No. 4, Scott Technology Park, Scott Township, Pennsylvania, as more particularly described in the Lease (the “Leased
Premises”).

 

(b)               
Guarantor is [DESCRIBE RELATIONSHIP OF GUARANTOR TO TENANT] and is therefore receiving a substantial benefit for executing
this Guaranty.

 

(c)                
Landlord would not have entered into the Lease with Tenant without having received the Guaranty executed by Guarantor as
an inducement to Landlord.

 

(d)               
By this Guaranty, Guarantor intends to absolutely, unconditionally and irrevocably guarantee the full, timely, and complete
(i) payment of all rent and other sums required to be paid by Tenant under the Lease and any other indebtedness of Tenant, (ii)
performance of all other terms, covenants, conditions and obligations of Tenant arising out of the Lease (including, without limitation,
reasonable attorneys’ fees and disbursements and all litigation costs and expenses incurred or payable by Landlord or for
which Landlord may be responsible or liable, or caused by any such uncured default), and (iii) payment of any and all expenses
(including reasonable attorneys’ fees and expenses and litigation expenses) incurred by Landlord in enforcing any of the
rights under the Lease or this Guaranty within five (5) days after Landlord’s demand thereafter (collectively, the “Guaranteed
Obligations”).

 

2.                  
Guaranty. From and after the Execution Date (as such term is defined under the Lease), Guarantor absolutely, unconditionally
and irrevocably guarantees, as principal obligor and not merely as surety, to Landlord, the full, timely and unconditional payment
and performance, of the Guaranteed Obligations strictly in accordance with the terms of the Lease, as such Guaranteed Obligations
may be modified, amended, extended or renewed from time to time. This is a Guaranty of payment and performance and not merely of
collection. Guarantor agrees that Guarantor is primarily liable for and responsible for the payment and performance of the Guaranteed
Obligations. Guarantor shall be bound by all of the provisions, terms, conditions, restrictions and limitations contained in the
Lease which are to be observed or performed by Tenant, the same as if Guarantor was named therein as Tenant with joint and several
liability with Tenant, and any remedies that Landlord has under the Lease against Tenant shall apply to Guarantor as well. If Tenant
defaults in any Guaranteed Obligation under the Lease, Guarantor shall in lawful money of the United States, pay to Landlord on
demand the amount due and owing under the Lease. Guarantor waives any rights to notices of acceptance, modifications, amendment,
extension or breach of the Lease. If Guarantor is a natural person, it is expressly agreed that this guaranty shall survive the
death of such guarantor and shall continue in effect. The obligations of Guarantor under this Guaranty are independent of the obligations
of Tenant or any other guarantor. Guarantor acknowledges that this Guaranty and Guarantor’s obligations and liabilities under
this Guaranty are and shall at all times continue to be absolute and unconditional in all respects and shall be the separate and
independent undertaking of Guarantor without regard to the genuineness, validity, legality or enforceability of the Lease, and
shall at all times be valid and enforceable irrespective of any other agreements or circumstances of any nature whatsoever which
might otherwise constitute a defense to this Guaranty and the obligations and liabilities of Guarantor under this Guaranty or the
obligations or liabilities of any other person or entity (including, without limitation, Tenant) relating to this Guaranty or the
obligations or liabilities of Guarantor hereunder or otherwise with respect to the Lease or to Tenant. Guarantor hereby absolutely,
unconditionally and irrevocably waives any and all rights it may have to assert any defense, set-off (except to the extent expressly
provided for under the Lease), counterclaim or cross-claim of any nature whatsoever with respect to this Guaranty or the obligations
or liabilities of Guarantor under this Guaranty or the obligations or liabilities of any other person or entity (including, without
limitation, Tenant) relating to this Guaranty or the obligations or liabilities of Guarantor under this Guaranty or otherwise with
respect to the Lease, in any action or proceeding brought by the holder hereof to enforce the obligations or liabilities of Guarantor
under this Guaranty. This Guaranty sets forth the entire agreement and understanding of Landlord and Guarantor, and Guarantor acknowledges
that no oral or other agreements, understandings, representations or warranties exist with respect to this Guaranty or with respect
to the obligations or liabilities of Guarantor under this Guaranty. The obligations of Guarantor under this Guaranty shall be continuing
and irrevocable (a) during any period of time when the liability of Tenant under the Lease continues, and (b) until all of the
Guaranteed Obligations have been fully discharged by payment, performance or compliance. If at any time all or any part of any
payment received by Landlord from Tenant or Guarantor or any other person under or with respect to the Lease or this Guaranty has
been refunded or rescinded pursuant to any court order, or declared to be fraudulent or preferential, or are set aside or otherwise
are required to be repaid to Tenant, its estate, trustee, receiver or any other party, including as a result of the insolvency,
bankruptcy or reorganization of Tenant or any other party (an “Invalidated Payment”), then Guarantor’s
obligations under the Guaranty shall, to the extent of such Invalidated Payment be reinstated and deemed to have continued in existence
as of the date that the original payment occurred. This Guaranty shall not be affected or limited in any manner by whether Tenant
may be liable, with respect to the Guaranteed Obligations individually, jointly with other primarily, or secondarily.

 

     

     

    

 

3.                  
No Impairment of Guaranteed Obligations. Guarantor further agrees that Guarantor’s liability for the Guaranteed
Obligations shall in no way be released, discharged, impaired or affected or subject to any counterclaim, setoff or deduction by
(a) any waiver, consent, extension, indulgence, compromise, release, departure from or other action or inaction of Landlord under
or in respect of the Lease or this Guaranty, or any obligation or liability of Tenant, or any exercise or non-exercise of any right,
remedy, power or privilege under or in respect to the Lease or this Guaranty, (b) any change in the time, manner or place of payment
or performance of the Guaranteed Obligations, (c) the acceptance by Landlord of any additional security or any increase, substitution
or change therein, (d) the release by Landlord of any security or any withdrawal thereof or decrease therein, (e) any assignment
of the Lease or any subletting of all or any portion of the Leased Premises (with or without Landlord’s consent), (f) any
holdover by Tenant beyond the term of the Lease (g) any termination of the Lease, (h) any release or discharge of Tenant in any
bankruptcy, receivership or other similar proceedings, (i) the impairment, limitation or modification of the liability of Tenant
or the estate of Tenant in bankruptcy or of any remedy for the enforcement of Tenant’s liability under the Lease resulting
from the operation of any present or future provisions of any bankruptcy code or other statute or from the decision in any court,
or the rejection or disaffirmance of the Lease in any such proceedings, (j) any merger, consolidation, reorganization or similar
transaction involving Tenant, even if Tenant ceases to exist as a result of such transaction, (k) the change in the corporate relationship
between Tenant and Guarantor or any termination of such relationship, (l) any change in the direct or indirect ownership of all
or any part of the shares in Tenant, or (m) to the extent permitted under applicable law, any other occurrence or circumstance
whatsoever, whether similar or dissimilar to the foregoing, which might otherwise constitute a legal or equitable defense or discharge
of the liabilities of Guarantor or which might otherwise limit recourse against Guarantor. Guarantor further understands and agrees
that Landlord may at any time enter into agreements with Tenant to amend and modify the Lease, and may waive or release any provision
or provisions of the Lease, and, with reference to such instruments, may make and enter into any such agreement or agreements as
Landlord and Tenant may deem proper and desirable, without in any manner impairing or affecting this Guaranty or any of Landlord’s
rights hereunder or Guarantor’s obligations hereunder, unless otherwise agreed in writing thereunder or under the Lease.

 

4.                  
Remedies.

 

a)            If Tenant defaults
with respect to the Guaranteed Obligations, and if Guarantor does not fulfill Tenant’s obligations within thirty (30) days
following its receipt of written notice of such default from Landlord, Landlord may at its election proceed immediately against
Guarantor, Tenant, or any combination of Tenant, Guarantor, and/or any other guarantor. It is not necessary for Landlord, in order
to enforce payment and performance by Guarantor under this Guaranty, first or contemporaneously to institute suit or exhaust remedies
against Tenant or other liable for any of the Guaranteed Obligations or to enforce rights against any collateral securing any of
it. Guarantor hereby waives any right to require Landlord to join Tenant in any action brought hereunder or to commence any action
against or obtain any judgment against Tenant or to pursue any other remedy or enforce any other right. If any portion of the Guaranteed
Obligations terminates and Landlord continues to have any rights that it may enforce against Tenant under the Lease after such
termination, then Landlord may at its election enforce such rights against Guarantor. Unless and until all Guaranteed Obligations
have been fully satisfied, Guarantor shall not be released from its obligations under this Guaranty irrespective of: (i) the exercise
(or failure to exercise) by Landlord of any of Landlord’s rights or remedies (including, without limitation, compromise or
adjustment of the Guaranteed Obligations or any part thereof); or (ii) any release by Landlord in favor of Tenant regarding the
fulfillment by Tenant of any obligation under the Lease.

 

     

     

    

 

b)           Notwithstanding
anything in the foregoing to the contrary, Guarantor hereby covenants and agrees to and with Landlord that Guarantor may be joined
in any action by or against Tenant in connection with the Lease. Guarantor also agrees that, in any jurisdiction, it will be conclusively
bound by the judgment in any such action by or against Tenant (wherever brought) as if Guarantor were a party to such action even
though Guarantor is not joined as a party in such action.

 

5.                  
Waivers. With the exception of the defense of prior payment, performance or compliance by Tenant or Guarantor of
or with the Guaranteed Obligations which Guarantor is called upon to pay or perform, or the defense that Landlord’s claim
against Guarantor is barred by the applicable statute of limitations, Guarantor hereby waives and releases all defenses of the
law of guaranty or suretyship to the extent permitted by law.

 

6.                  
Rights Cumulative. All rights, powers and remedies of Landlord under this Guaranty shall be cumulative and in addition
to all rights, powers and remedies given to Landlord by law.

 

7.                  
Representations and Warranties. Guarantor hereby represents and warrants that (a) Landlord has made no representation
to Guarantor as to the creditworthiness or financial condition of Tenant; (b) Guarantor has full power to execute, deliver and
carry out the terms and provisions of this Guaranty and has taken all necessary action to authorize the execution, delivery and
performance of this Guaranty; (c) Guarantor’s execution and delivery of, and the performance of its obligations under, this
Guaranty does not conflict with or violate any of Guarantor’s organizational documents, or any contract, agreement or decree
which Guarantor is a party to or which is binding on Guarantor; (d) the individual executing this Guaranty on behalf of Guarantor
has the authority to bind Guarantor to the terms and conditions of this Guaranty; (e) Guarantor has been represented by counsel
of its choice in connection with this Guaranty; (f) this Guaranty when executed and delivered shall constitute the legal, valid
and binding obligations of Guarantor enforceable against Guarantor in accordance with its terms; and (g) there is no action, suit,
or proceeding pending or, to the knowledge of Guarantor, threatened against Guarantor before or by any governmental authority which
questions the validity or enforceability of, or Guarantor’s ability to perform under, this Guaranty.

 

8.                  
Subordination. In the event of Tenant’s insolvency or the disposition of the assets of Tenant, through bankruptcy,
by an assignment for the benefit of creditors, by voluntary liquidation, or otherwise, the assets of Tenant applicable to the payment
of all claims of Landlord and/or Guarantor shall be paid to Landlord and shall be first applied by Landlord to the Guaranteed Obligations.
Any indebtedness of Tenant now or hereafter held by Guarantor, whether as original creditor or assignee or by way of subrogation,
restitution, reimbursement, indemnification or otherwise, is hereby subordinated in right of payment to the Guaranteed Obligations.
So long as an uncured event of default exists under the Lease, (a) at Landlord’s written request, Guarantor shall cause Tenant
to pay to Landlord all or any part of any funds invested in or loaned to Tenant by Guarantor which Guarantor is entitled to withdraw
or collect and (b) any such indebtedness or other amount collected or received by Guarantor shall be held in trust for Landlord
and shall forthwith be paid over to Landlord to be credited and applied against the Guaranteed Obligations. Subject to the foregoing,
Guarantor shall be entitled to receive from Landlord any amounts that are, from time to time, due to Guarantor in the ordinary
course of business. Until all of Tenant’s obligations under the Lease are fully performed, Guarantor shall have no right
of subrogation against Tenant by reason of any payments, acts or performance by Guarantor under this Guaranty.

 

9.                  
Governing Law. This Guaranty shall be governed by and construed in accordance with the laws of the State of Pennsylvania,
United States of America, without regard to principles of conflicts of laws. TO THE FULLEST EXTENT PERMITTED BY LAW, GUARANTOR
HEREBY UNCONDITIONALLY AND IRREVOCABLY WAIVES ANY CLAIM TO ASSERT THAT THE LAW OF ANY OTHER JURISDICTION GOVERNS THIS GUARANTY.
EACH PARTY IRREVOCABLY CONSENTS TO THE JURISDICTION OF THE STATE COURTS SITUATED IN OR HAVING JURISDICTION OVER SCOTT TOWNSHIP,
PENNSYLVANIA IN ANY ACTION THAT MAY BE BROUGHT FOR THE ENFORCEMENT OF THIS GUARANTY (WITH THE EXPRESS AGREEMENT THAT NO ACTION
MAY BE BROUGHT IN FEDERAL COURT RELATING IN ANY WAY TO THIS GUARANTY OR THE LEASE).

 

     

     

    

 

10.               
Attorneys’ Fees. In the event any litigation or other proceeding (“Proceeding”) is initiated
by any party against any other party to enforce this Guaranty, the prevailing party in such Proceeding shall be entitled to recover
from the unsuccessful party all costs, expenses, and actual reasonable attorneys’ fees relating to or arising out of such
Proceeding.

 

11.               
Modification. This Guaranty may be modified only by a contract in writing executed by Guarantor and Landlord.

 

12.               
Invalidity. If any provision of the Guaranty shall be invalid or unenforceable, the remainder of this Guaranty shall
not be affected by such invalidity or unenforceability. In the event, and to the extent, that this Guaranty shall be held ineffective
or unenforceable by any court of competent jurisdiction, then Guarantor shall be deemed to be a tenant under the Lease with the
same force and effect as if Guarantor were expressly named as a co-tenant therein with joint and several liability.

 

13.               
Successors and Assigns. Unless otherwise agreed in writing or under the Lease, this Guaranty shall be binding upon
and shall inure to the benefit of the successors-in-interest and assigns of each party to this Guaranty.

 

14.               
Notices. Any notice, consent, demand, invoice, statement or other communication required or permitted to be given
hereunder shall be in writing and shall be given by (a) personal delivery, (b) overnight delivery with a reputable international
overnight delivery service, such as FedEx, or (c) facsimile or email transmission, so long as such transmission is followed within
one (1) business day by delivery utilizing one of the methods described in subsections (a) or (b). Any such notice, consent, demand,
invoice, statement or other communication shall be deemed delivered (x) upon receipt, if given in accordance with subsection (a);
(y) one business (1) day after deposit with a reputable international overnight delivery service, if given if given in accordance
with subsection (b); or (z) upon transmission, if given in accordance with subsection (c). Except as otherwise stated in this Guaranty,
any notice, consent, demand, invoice, statement or other communication required or permitted to be given pursuant to this Guaranty
shall be addressed to Guarantor or Landlord at the address set forth above in the introductory paragraph of this Guaranty. Either
party may, by notice to the other given pursuant to this Section, specify additional or different addresses for notice purposes.

 

15.               
Waiver. Any waiver of a breach or default under this Guaranty must be in a writing that is duly executed by Landlord
and shall not be a waiver of any other default concerning the same or any other provision of this Guaranty. No delay or omission
in the exercise of any right or remedy shall impair such right or remedy or be construed as a waiver.

 

16.               
Withholding. Unless otherwise agreed in the Lease, any and all payments by Guarantor to Landlord under this Guaranty
shall be made free and clear of and without deduction for any and all present or future taxes, duties, levies, imposts, deductions,
assessments, fees, withholdings or similar charges, and all liabilities with respect thereto (collectively, “Taxes”).
If Guarantor shall be required by any applicable laws to deduct any Taxes from or in respect of any sum payable under this Guaranty
to Landlord: (a) the sum payable shall be increased as necessary so that after making all required deductions, the Landlord receives
an amount equal to the sum it would have received had no such deductions been made; (b) Guarantor shall make such deductions; and
(c) Guarantor shall pay the full amount deducted to the relevant taxation authority or other authority in accordance with applicable
laws.

 

17.               
 Financial Condition of Tenant. Landlord shall have no obligation to disclose or discuss with Guarantor Landlord’s
assessment of the financial condition of Tenant. Guarantor has adequate means to obtain information from Tenant on a continuing
basis concerning the financial condition of Tenant and its ability to perform its Guaranteed Obligations, and Guarantor assumes
responsibility for being and keeping informed of Tenant’s financial condition and of all circumstances bearing upon the risk
of Tenant’s failure to perform the Guaranteed Obligations.

 

     

     

    

 

18.               
Bankruptcy. So long as the Guaranteed Obligations remain outstanding, Guarantor shall not, without Landlord’s
prior written consent, commence or join with any other person in commencing any bankruptcy or similar proceeding of or against
Tenant. Guarantor’s obligations hereunder shall not be reduced, limited, impaired, discharged, deferred, suspended or terminated
by any bankruptcy or similar proceeding (voluntary or involuntary) involving Tenant or by any defense that Tenant may have by reason
of an order, decree or decision of any court or administrative body resulting from any such proceeding. To the fullest extent permitted
by law, Guarantor will permit any trustee in bankruptcy, receiver, debtor in possession, assignee for the benefit of creditors
or similar person to pay to Landlord or allow the claim of Landlord in respect of any interest, fees, costs, expenses or other
Guaranteed Obligations accruing or arising after the date on which such case or proceeding is commenced.

 

19.               
Conveyance or Transfer. Without Landlord’s written consent, Guarantor shall not convey, sell, lease or transfer
any of its properties or assets to any person or entity to the extent that such conveyance, sale, lease or transfer could have
a material adverse effect on Guarantor’s ability to fulfill any of the Guaranteed Obligations.

 

20.               
[NOTE: ONLY WHERE GUARANTOR IS NOT A DIRECT OR INDIRECT PARENT OF TENANT: [Limitation on Obligations Guaranteed. 

 

(a)       Notwithstanding
any other provision hereof, the right of recovery against Guarantor under Section 2 shall not exceed $1.00 less than the
lowest amount that would render Guarantor’s obligations under Section 2 void or voidable under applicable law, including,
without limitation, the Uniform Fraudulent Conveyance Act, Uniform Fraudulent Transfer Act or any similar foreign, federal or state
law to the extent applicable to the guaranty set forth herein and the obligations of Guarantor hereunder. To effectuate the foregoing,
the Guaranteed Obligations in respect of the guarantee set forth in Section 2 at any time shall be limited to the maximum amount
as would result in the Guaranteed Obligations with respect thereto not constituting a fraudulent transfer or conveyance after giving
full effect to the liability under such guarantee set forth in Section 2 and its related contribution rights, but before taking
into account any liabilities under any other guarantee by Guarantor. For purposes of the foregoing, all guarantees of Guarantor
other than the guarantee under Section 2 will be deemed to be enforceable and payable after the guaranty under Section 2. To the
fullest extent permitted by applicable law, this Section shall be for the benefit solely of creditors and representatives of creditors
of Guarantor and not for the benefit of Guarantor or the holders of any equity interest in Guarantor.

 

(b)       Guarantor
agrees that obligations may at any time and from time to time be incurred or permitted in an amount exceeding the maximum liability
of Guarantor under Section 2 without impairing the guarantee contained in Section 2 or affecting Landlord’s rights and remedies
hereunder.]]

 

21.               
Financials. To induce Landlord to enter into the Lease, Guarantor shall, within ninety (90) days after the end of
Guarantor’s financial year, furnish Landlord with a certified copy of Guarantor’s year-end unconsolidated financial
statements for the previous year, audited by a nationally recognized accounting firm. If audited financial statements are not
otherwise prepared, then Guarantor may satisfy the requirement to provide audited financial statements by providing in lieu thereof
unaudited financial statements prepared in accordance with GAAP and certified by the chief financial officer of Guarantor as correct
and complete copies of such financial statements, fairly presenting Guarantor’s financial condition as of the time set forth
therein and having been prepared in accordance with GAAP. Guarantor also acknowledges and agrees to comply with the financial
reporting requirements set forth in Section 33.1 of the Lease.

 

22.               
Joint and Several Liability. Guarantor’s liability under this Guaranty shall be joint and several with any
and all other Guarantors in accordance with the terms and conditions of the Lease.

 

[REMAINDER OF THIS PAGE IS INTENTIONALLY
LEFT BLANK]

 

     

     

    

 

IN WITNESS WHEREOF,
Guarantor has caused this Guaranty to be signed by its respective officer thereunto duly authorized, all as of the date first written
above.

 

GUARANTOR

 

[_______],

a [_______]

 

 

	By:	 	 
	Name:   	 	 
	Title:	 	 

 

     

     

    

 

EXHIBIT E

 

TENANT WORK INSURANCE SCHEDULE

 

Tenant shall be responsible
for requiring all of Tenant contractors doing construction or renovation work to purchase and maintain such insurance as shall
protect it from the claims set forth below which may arise out of or result from any Tenant Work whether such Tenant Work is completed
by Tenant or by any Tenant contractors or by any person directly or indirectly employed by Tenant or any Tenant contractors, or
by any person for whose acts Tenant or any Tenant contractors may be liable:

 

		1.	Claims under workers’ compensation, disability benefit and other similar employee benefit
acts which are applicable to the Tenant Work to be performed.

 

		2.	Claims for damages because of bodily injury, occupational sickness or disease, or death of employees
under any applicable employer’s liability law.

 

		3.	Claims for damages because of bodily injury, or death of any person other than Tenant’s or
any Tenant contractors’ employees.

 

		4.	Claims for damages insured by usual personal injury liability coverage which are sustained (a)
by any person as a result of an offense directly or indirectly related to the employment of such person by Tenant or any Tenant
contractors or (b) by any other person.

 

		5.	Claims for damages, other than to the Tenant Work itself, because of injury to or destruction of
tangible property, including loss of use therefrom.

 

		6.	Claims for damages because of bodily injury or death of any person or property damage arising out
of the ownership, maintenance or use of any motor vehicle.

 

Tenant contractors’ Commercial General
Liability Insurance shall include premises/operations (including explosion, collapse and underground coverage if such Tenant Work
involves any underground work), elevators, independent contractors, products and completed operations, and blanket contractual
liability on all written contracts, all including broad form property damage coverage.

 

Tenant contractors’ Commercial General,
Automobile, Employers and Umbrella Liability Insurance shall be written for not less than limits of liability as follows:

 

	
        a.       Commercial
        General Liability:

        Bodily Injury and Property Damage

         
	
        Commercially reasonable amounts, but in
        any event no less than $1,000,000 per occurrence and $2,000,000 general aggregate, with $2,000,000 products and completed operations
        aggregate.

         

	
        b.       Commercial
        Automobile Liability:

        Bodily Injury and Property Damage

         
	$1,000,000 per accident
	
        c.       Employer’s
        Liability:

        Each Accident

        Disease – Policy Limit

        Disease – Each Employee

         
	
         

        $500,000

        $500,000

        $500,000

	
        d.       Umbrella
        Liability:

        Bodily Injury and Property Damage
	
        Commercially reasonable amounts (excess
        of coverages a, b and c above), but in any event no less than $3,000,000 per occurrence / aggregate.

         

 

     

     

    

 

All subcontractors
for Tenant contractors shall carry the same coverages and limits as specified above, unless different limits are reasonably approved
by Landlord. The foregoing policies shall contain a provision that coverages afforded under the policies shall not be canceled
or not renewed until at least thirty (30) days’ prior written notice has been given to the Landlord. Certificates of insurance
including required endorsements showing such coverages to be in force shall be filed with Landlord prior to the commencement of
any Tenant Work and prior to each renewal. Coverage for completed operations must be maintained for the lesser of ten (10) years
and the applicable statue of repose following completion of the Tenant Work, and certificates evidencing this coverage must be
provided to Landlord. The minimum A.M. Best’s rating of each insurer shall be A- VII. Landlord and its mortgagees shall be
named as an additional insureds under Tenant contractors’ Commercial General Liability, Commercial Automobile Liability and
Umbrella Liability Insurance policies as respects liability arising from work or operations performed, or ownership, maintenance
or use of autos, by or on behalf of such contractors. Each contractor and its insurers shall provide waivers of subrogation with
respect to any claims covered or that should have been covered by valid and collectible insurance, including any deductibles or
self-insurance maintained thereunder.

 

If any contractor’s
work involves the handling or removal of asbestos (as determined by Landlord in its sole and absolute discretion), such contractor
shall also carry Pollution Legal Liability insurance. Such coverage shall include bodily injury, sickness, disease, death or mental
anguish or shock sustained by any person; property damage, including physical injury to or destruction of tangible property (including
the resulting loss of use thereof), clean-up costs and the loss of use of tangible property that has not been physically injured
or destroyed; and defense costs, charges and expenses incurred in the investigation, adjustment or defense of claims for such damages.
Coverage shall apply to both sudden and non-sudden pollution conditions including the discharge, dispersal, release or escape of
smoke, vapors, soot, fumes, acids, alkalis, toxic chemicals, liquids or gases, waste materials or other irritants, contaminants
or pollutants into or upon land, the atmosphere or any watercourse or body of water. Claims-made coverage is permitted, provided
the policy retroactive date is continuously maintained prior to the Commencement Date, and coverage is continuously maintained
during all periods in which Tenant occupies the Premises. Coverage shall be maintained with limits of not less than $1,000,000
per incident with a $2,000,000 policy aggregate.

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00299-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00299-of-00352.parquet"}]]