Document:

Third Amendment to Lease

 Exhibit 10.3 
 THIRD AMENDMENT TO LEASE 
 This THIRD AMENDMENT TO LEASE
(“Amendment”) is made and entered into as of the 27th day of September, 2012 (the “Effective Date”), by and between KNICKERBOCKER PROPERTIES, INC. XXXIII, a Delaware corporation (“Landlord”), and
MEDIVATION, INC., a Delaware corporation (“Tenant”). 
 RECITALS: 

A. Landlord and Tenant entered into that certain Office Lease dated as of December 28, 2011 (the “Original Lease”),
pursuant to which Landlord leased to Tenant and Tenant leased from Landlord those certain premises (the “Original Premises”) consisting of the entire rentable area (which the parties hereto stipulate contains 57,172 rentable square
feet) on the thirty-fifth (35th) and thirty-sixth (36th) floors of that certain building located as 525 Market Street, San Francisco, California (the “Building”). 

B. Landlord and Tenant entered into that certain (i) First Amendment to Lease dated as of December 28, 2011 (“First
Amendment”), pursuant to which certain technical modifications were made to the Original Lease and (ii) that certain Second Amendment to Lease dated as of July 6, 2012 (“Second Amendment”), pursuant to which
certain dates and terms set forth in the Original Lease were confirmed and ratified. The Original Lease, as modified by the First Amendment and the Second Amendment, is referred to herein in the “Lease.” 

C. Landlord has caused a non-disturbance agreement to be executed and delivered to Tenant, which satisfies the requirements of
Section 25.03 of the Original Lease. 
 D. The parties desire to further amend the Lease to (i) expand the Original
Premises to include those certain premises depicted on Exhibit “A” attached hereto, comprising the entire rentable area (which the parties hereto stipulate contains 28,526 rentable square feet) on the thirty-eighth (38th) floor
of the Building (the “Expansion Space”), and (ii) otherwise modify the Lease, all upon the terms and conditions hereinafter set forth. 
 NOW, THEREFORE, in consideration of the foregoing recitals and the mutual covenants contained herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby
acknowledged, the parties hereto agree as follows: 
 1. Capitalized Terms. All capitalized terms used herein shall have
the same meanings given such terms in the Lease unless expressly superseded by the terms of this Amendment. 
 2.
Tenant’s Lease of Expansion Space. 
 (a) From and after the Expansion Space Commencement Date (as defined in
Section 3 below), the Original Premises shall be expanded to include the Expansion Space for the Expansion Space Term (as defined in Section 3 below), and shall be leased by Tenant on the same terms and conditions set forth in the Lease,
subject to the modifications set forth in this Amendment. From and after the Expansion Space Commencement Date, the term “Premises” as used in the Lease shall mean the Original Premises and the Expansion Space. 

 (b) From and after the Expansion Space Commencement Date, and for all purposes of the Lease
(as amended by this Amendment), the definition of the term “Rentable Area of the Premises” set forth in Article 1(g) of the Original Lease is hereby deleted and the following text is substituted in lieu thereof: “85,698
rentable square feet.” 
 (c) The option to extend the Term set forth in Exhibit “H” of the Original Lease
(the “Option”) shall, by virtue of this Amendment, apply to either (i) the Original Premises and the Expansion Space (i.e., the 35th, 36th, and 38th floors of the Building) or (ii) the Original Premises only (i.e., the
35th and the 36th floors of the Building). It is the intent of the parties hereto that the Option shall apply to the entirety of the 35th, 36th, and 38th floors of the Building as a single unit, or to just the 35th and 36th floors of the Building.
If Tenant exercises the Option in accordance with the terms of such Exhibit “H,” Tenant’s Interest Notice delivered in accordance with such Exhibit “H” shall expressly and irrevocably elect to apply the Option
to either the Original Premises only (i.e., the 35th and 36th floors of the Building) or the entire Premises (i.e., the 35th, 36th, and 38th floors of the Building) (the “Option Space Election”). If Tenant fails to expressly include
the Option Space Election in the Interest Notice, Tenant shall be irrevocably deemed to apply the Option to the entire Premises (i.e., the 35th, 36th, and 38th floors of the Building) and not to any lesser part thereof. All other terms and
provisions of such Exhibit “H” shall continue in full force and effect. 
 (d) Tenant’s acceptance of
possession of the Expansion Space (whether before or after the Expansion Space Commencement Date) shall constitute Tenant’s acknowledgment that the Expansion Space is in good order and satisfactory condition. For purposes of determining whether
Tenant has accepted possession of the Expansion Space, Tenant shall be deemed to have done so when Tenant first moves any of its personnel and/or furnishings and/or equipment into the Expansion Space, except to the extent that Tenant is explicitly
authorized in the Lease or by Landlord’s agreement in writing to do any of the foregoing without being deemed to have accepted possession of the Expansion Space. 
 3. Commencement Date, Expiration Date and Term. Subject to the Abated Rent Period (as set forth in Section 4(b) below), the term of Tenant’s lease of the Expansion Space shall
(i) commence on the earlier to occur of (x) January 1, 2013, which date shall be extended on a day-for-day basis for Landlord Delays (as such term is defined in the Workletter Agreement attached hereto as
Exhibit “B” and made a part hereof) and (y) the date Tenant occupies the Expansion Space or commences its business operations therefrom (the “Expansion Space Commencement Date”), and (ii) expire on
the Expiration Date set forth in Lease Article 1(j) and as confirmed pursuant to the Second Amendment (the “Expansion Space Expiration Date”). The period of time commencing on the Expansion Space Commencement Date and expiring on
the Expansion Space Expiration Date shall be referred to herein as the “Expansion Space Term.” Landlord shall deliver the Expansion Space to Tenant upon the full execution and delivery of this Amendment by Landlord and Tenant’s
delivering the LOC Amendment (as defined in Section 8(a) below) and the first full month’s Base Rent applicable to the Expansion Space for the Expansion Space Term. In the event the Expansion Space Commencement Date is not the first day of
a calendar month (such month in which the Expansion Space Commencement Date occurs being referred to herein as the “Partial Month”) the Monthly Base Rent for the Expansion Space for such Partial Month shall be prorated as provided
in the Lease. Once the Expansion Space Commencement Date has been determined, Landlord and Tenant shall execute 

  
 2 

 
a written confirmation stating the actual Expansion Space Commencement Date, but failure of the parties to execute such a writing shall have no impact on the Expansion Space Commencement Date.

 4. Base Rent. 
 (a) The Base Rent payable by Tenant for the Expansion Space shall be calculated separate and apart from the Base Rent payable by Tenant for the Original Premises. During the Expansion Space Term, the Base
Rent payable by Tenant for the Expansion Space shall be as set forth in the following schedule: 
  

													
	 Months of Expansion Space Term
	  	Annual Base Rent	 	  	Monthly Base Rent	 	  	Annual Rental Rate
per
Rentable Square Foot of the
Expansion Space	 
				
	 Expansion Space Commencement Date through the last day of December 2013
	  	$	1,768,612.00	  	  	$	147,384.33	  	  	$	62.00	  
				
	 January 2014 through the last day of December 2014
	  	$	1,797,138.00	  	  	$	149,761.50	  	  	$	63.00	  
				
	 January 2015 through the last day of December 2015
	  	$	1,825,664.00	  	  	$	152,138.67	  	  	$	64.00	  
				
	 January 2016 through the last day of December 2016
	  	$	1,854,190.00	  	  	$	154,515.83	  	  	$	65.00	  
				
	 January 2017 through the last day of December 2017
	  	$	1,882,716.00	  	  	$	156,893.00	  	  	$	66.00	  
				
	 January 2018 through the last day of December 2018
	  	$	1,911,242.00	  	  	$	159,270.17	  	  	$	67.00	  
				
	 January 2019 through the last day of June 2019
	  	 	Not Applicable	  	  	$	161,647.33	  	  	$	68.00	  

 (b) Provided that there is not a continuing Event of Default beyond any applicable notice and cure
periods under the Lease, Landlord hereby agrees to conditionally abate Tenant’s obligation to pay Monthly Base Rent (the “Abated Rent”) for the entire Expansion Space only (and not the Original Premises) for the first full
calendar month of the Expansion Space Term (“Abated Rent Period”). During the Abated Rent Period, Tenant shall remain responsible for the payment of all of its other monetary obligations under the Lease and

  
 3 

 
this Amendment. In the event an Event of Default shall occur beyond any applicable notice and cure periods hereunder, the Abated Rent shall be immediately due and payable by Tenant and shall
constitute “rent” payable under the Lease. 
 5. Operating Expenses and Tax Expenses. 

(a) Tenant’s Percentage Share (Direct Expenses) is 5.6220% for the Original Premises and shall, as of the Expansion Space
Commencement Date, be increased by 2.8051% to an aggregate of 8.4271%. Tenant’s Percentage Share (Taxes) is 5.5402% for the Original Premises and shall, as of the Expansion Space Commencement Date, be increased by 2.7643% to an aggregate of
8.3045%. 
 (b) The Base Year used to calculate increases in Tenant’s Percentage Share (Direct Expenses) and Tenant’s
Percentage Share (Taxes) with respect to the Expansion Space only shall be the 2013 calendar year. The Base Year used to calculate Tenant’s Percentage Share (Direct Expenses) and Tenant’s Percentage Share (Taxes) with respect to the
Original Premises shall remain 2012. Tenant shall pay Tenant’s Percentage Share (Direct Expanses) and Tenant’s Percentage Share (Taxes) with respect to the Original Premises and the Expansion Space in accordance with Lease Articles 5 and
6, respectively. 
 6. Condition of Expansion Space. Tenant hereby accepts the Expansion Space in its current “AS
IS” condition without any obligation on Landlord’s part to construct or pay for any tenant improvements or refurbishment work in the Expansion Space. Tenant shall commence promptly on and after the Expansion Space Commencement Date to
construct the Tenant Improvements (as defined in Exhibit “B” attached hereto and made a part hereof) to the Expansion Space in accordance with the terms of the Workletter attached hereto and made a part of hereof as Exhibit
“B.” 
 7. Security Deposit; First Month’s Base Rent. 

(a) Landlord is currently holding a Letter of Credit with a Stated Amount equal to $5,145,480.00. On the Expansion Space Commencement
Date, Tenant shall cause the Letter of Credit provider (currently Bank of America, N.A.) to deliver an amendment to the Letter of Credit in form and substance reasonably satisfactory to Landlord (“LOC Amendment”) increasing the
Stated Amount by $2,881,126.00 to the aggregate amount of $8,026,606.00. All references in the Lease to “Stated Amount” shall mean the amount of $8,026,606.00, and all references in the Lease to “Letter of Credit”
shall be deemed to mean the Letter of Credit as amended by the LOC Amendment. 
 (b) On the Expansion Space Commencement Date,
Tenant shall pay to Landlord (i) the first installment of Monthly Base Rent attributable to the Expansion Space and (ii) the Monthly Base Rent for any Partial Month. 
 8. Right of First Offer. Schedule 1 to Exhibit G to the Original Lease is hereby deleted and replaced with Schedule 1 attached hereto and made a part hereof. 

9. Non-Disturbance Agreement. Landlord shall use commercially reasonable efforts to request a non-disturbance agreement (the
“NDA”) with respect to the Expansion Space from 

  
 4 

 
Landlord’s first mortgage lender (“Lender”) on Lender’s standard form and at Tenant’s sole cost and expense. Execution and delivery of the NDA is not a condition
precedent to the effectiveness of this Amendment. 
 10. Amendment Brokers. Each of Landlord and Tenant hereby represents
and warrants to the other that it has not had any dealings with any real estate broker or agent in connection with the negotiation of this Amendment other than Cushman & Wakefield of California, Inc. for Landlord and Jones Lang LaSalle for
Tenant (collectively, the “Amendment Brokers”). Each party agrees to indemnify and defend the other party harmless from any and all claims, demands, losses, liabilities, lawsuits, judgments, and costs and expenses (including,
without limitation, reasonable attorneys’ fees) with respect to any leasing commission or equivalent compensation claimed by any broker or agent other than the Amendment Brokers. Landlord agrees to compensate the Amendment Brokers in accordance
with a separate agreement. 
 11. No Further Modification. Except as set forth in this Amendment, all of the terms and
provisions of the Lease shall remain unmodified and in full force and effect. 
 [signatures on following page] 

  
 5 

 IN WITNESS WHEREOF, the parties have caused this Amendment to be duly executed by their duly
authorized representatives as of the date first above written. 
  

											
		 	“LANDLORD”:	 		 	KNICKERBOCKER PROPERTIES, INC. XXXIII, a Delaware corporation
					
		 		 		 	By:	 	 /s/ Steven M. Zaun

		 		 		 		 	Steven M. Zaun
		 		 		 		 	Its: Vice President
				
		 	“TENANT”:	 		 	MEDIVATION, INC., a Delaware corporation
					
		 		 		 	By:	 	 /s/ Patrick Machado

		 		 		 		 	Name:	 	 Patrick Machado

		 		 		 		 	Title:	 	 CFO & CBO

					
		 		 		 	By:	 	  

		 		 		 		 	Name:	 	  

		 		 		 		 	Title:	 	  

 Schedule “1” 

(to Original Lease Exhibit G) 
 Tenants occupying a portion of 37th floor: 
 Spencer Stuart (Suite 3700) — lease scheduled to
expire August 31, 2013 
 ClearSlide, Inc. (Suite 3750) — lease scheduled to expire February 28, 2015 

  
 Schedule 1

 1 

 EXHIBIT “A” 

THE EXPANSION SPACE 
  

 

  
 EXHIBIT A

 1 

 EXHIBIT “B” 

WORKLETTER AGREEMENT 
 This Workletter Agreement (the “Workletter”) is executed simultaneously with and is an exhibit to that certain Third Amendment to Lease (the “Amendment”), dated as of the
date hereof between KNICKERBOCKER PROPERTIES, INC. XXXIII, a Delaware corporation (“Landlord”), and MEDIVATION, INC., a Delaware corporation (“Tenant”), pursuant to which Tenant is leasing certain expansion space
more particularly described in the Amendment (the “Expansion Space”) at 525 Market Street, San Francisco, California (the “Building”). Capitalized terms not otherwise defined herein shall have the meanings assigned
thereto in the Amendment. In consideration of the parties entering into the Amendment and of the mutual promises and covenants hereinafter contained, Landlord and Tenant hereby agree as follows: 

 

	 	1.	Proposed and Final Plans. 

(a) Tenant shall cause to be prepared and delivered to Landlord, for Landlord’s approval, the following proposed preliminary space
plan (“Proposed Plans”) for all improvements Tenant desires to complete or have completed in the Expansion Space (the “Tenant Improvements”) which shall include the design standards set forth on Schedule
“B-1”: 
 (i) Architectural drawings (consisting of floor construction plan, ceiling lighting and layout, power, and
telephone plan). 
 (ii) Mechanical drawings (consisting of HVAC, electrical (including any UPS equipment), telephone, and
plumbing). Tenant acknowledges that part of the Tenant Improvements shall include (but shall not be limited to) the replacement of the existing Tuttle & Bailey terminal air boxes located in the Expansion Space with Building-standard Titus
VAV boxes, and that all such Titus VAV boxes shall comply with the Building’s Replacement VAV Box Design Criteria (August 26, 2011). 
 (iii) Finish schedule (consisting of wall finishes and floor finishes and miscellaneous details, including all window treatments which shall be Building-standard “Mecho” shades throughout the
Expansion Space). 
 (b) All architectural drawings shall be prepared at Tenant’s sole cost and expense (subject to
Section 3, below) by a licensed architect designated by Tenant and approved by Landlord, whom Tenant shall employ. Tenant shall deliver one set of reproducible architectural drawings to Landlord. All mechanical drawings shall be prepared at
Tenant’s sole cost and expense by a licensed engineer designated by Landlord, whom Tenant shall employ. Tenant shall reimburse Landlord for all reasonable out-of-pocket costs incurred by Landlord in reviewing the Proposed Plans and Final Plans.
All costs and charges by Landlord’s consultants shall be deducted from the Tenant Improvements Allowance (or charged to Tenant) without mark-up on an “open book” basis (which shall not exceed Twenty Thousand Dollars ($20,000.00)).

 (c) Within ten (10) business days after Landlord’s receipt of the architectural drawings, Landlord shall advise
Tenant of any changes or additional information required to obtain Landlord’s approval. 

  
 EXHIBIT B

 1 

 (d) Within ten (10) business days after receipt of mechanical drawings, Landlord shall
advise Tenant of any changes reasonably required to obtain Landlord’s approval. 
 (e) If Landlord disapproves of or
requests additional information regarding the Proposed Plans, Tenant shall, within fifteen (15) days thereafter, revise the Proposed Plans disapproved by Landlord and resubmit such plans to Landlord or otherwise provide such additional
information to Landlord. Landlord shall, within ten (10) business days after receipt of Tenant’s revised plans, advise Tenant of any additional changes which may be required to obtain Landlord’s approval. If Landlord reasonably
disapproves the revised plans specifying the reason therefor, or requests further additional information, Tenant shall, within ten (10) days of receipt of Landlord’s required changes, revise such plans and resubmit them to Landlord or
deliver to Landlord such further information as Landlord has requested. Landlord shall, again within ten (10) business days after receipt of Tenant’s revised plans, advise Tenant of further changes, if any, reasonably required for
Landlord’s approval. This process shall continue until Landlord has approved Tenant’s revised Proposed Plans. After the Proposed Plans are finally approved by Landlord, Tenant shall submit to Landlord construction drawings prepared by
Tenant’s architect (“Final Plans”) which shall contain all plans to be bid and built from and shall include all fully engineered mechanical, electrical, HVAC, plumbing, and fire life/safety drawings, all based upon the Proposed
Plans, and shall be compatible with the design, construction and equipment of the Building, comply with all Laws, be capable of logical measurement and construction, contain all such information as may be required for the construction of the Tenant
Improvements. 
 Landlord shall approve the Final Plans, or such portion as has from time to time been submitted, within fifteen
(15) business days after receipt of same or designate by notice given within such time period to Tenant the specific changes reasonably required to be made to the Working Drawings in order to correct any Design Problem and shall return the
Working Drawings to Tenant. Tenant shall make the minimum changes necessary in order to correct any such Design Problem and shall return the Working Drawings to Landlord, which Landlord shall approve or disapprove within fifteen (15) business
days after Landlord receives the revised Working Drawings. This procedure shall be repeated until all of the Working Drawings are finally approved by Landlord and written approval has been delivered to and received by Tenant. Landlord agrees not to
withhold its approval unreasonably. Tenant shall have no obligation to remove any portion of the Tenant Improvements at the end of the Term unless Landlord notifies Tenant, in a writing concurrently incorporated into Landlord’s approval of the
Final Plans, that such removal will be required. As used herein, “Design Problem” shall mean the Final Plans are deemed by Landlord in its good faith judgment to likely (i) have an adverse effect on the structural integrity of
the Building; (ii) cause possible damage to any of the Building systems (such as HVAC, fire life safety, plumbing, electrical, data/communication, mechanical, or security systems); (iii) be in non-compliance with applicable codes; or
(iv) have an adverse effect on the exterior appearance of the Building. 
 (f) All Proposed Plans and Final Plans shall
comply with all applicable statutes, ordinances, regulations, laws, and codes and with the requirements of Landlord’s fire insurance underwriters. Neither review nor approval by Landlord of the Proposed Plans and resulting Final Plans shall
constitute a representation or warranty by Landlord that such plans either (i) are complete or suitable for their intended purpose, or (ii) comply with applicable laws, ordinances, codes, regulations, or any insurance requirements, it
being expressly agreed by 

  
 EXHIBIT B

 2 

 
Tenant that Landlord assumes no responsibility or liability whatsoever to Tenant or to any other person or entity for such completeness, suitability or compliance. Tenant shall not make any
changes in the Final Plans without Landlord’s prior written approval, which shall not be unreasonably withheld or delayed; provided that Landlord may, in the exercise of its sole and absolute discretion, disapprove any proposed changes
adversely affecting the Building’s structure, any asbestos-containing materials, systems, equipment or the appearance or value of the Building. 
 (g) [Intentionally Deleted] 
 (h) Within thirty (30) days after written
request from Tenant, Landlord shall reimburse Tenant an amount not to exceed $4,278.90, for Tenant’s architect to complete a test fit/preliminary space plan for the Expansion Space, provided that Landlord has been provided with a CAD version of
Tenant’s test fit plans. 
 (i) Landlord has no objection to Tenant’s installing card key readers that integrate into
the Building’s security system (“Card Readers”) in the internal stairwells connecting the floors of the Premises. Tenant is responsible for obtaining all approvals therefore (including approvals of the San Francisco Fire
Department). Tenant may only use such stairwells for Tenant’s employees walking between floors and only if the original Tenant is occupying the entire Premises (that is, the Original Premises and the Expansion Space), and such use shall be
subject to Landlord’s rules and regulations established from time to time with respect to such use. Tenant acknowledges and agrees that prior to the expiration of the Expansion Space Term (or upon the earlier termination of the Expansion Space
Term), Tenant shall, at its sole cost and expense, remove the Card Readers and repair any damage to the Premises and the Building caused thereby. 
 (j) The term “Landlord Delay” as used in this Workletter shall mean: (1) delay in the giving of authorizations or approvals by Landlord beyond the periods set forth in this Workletter;
(2) delay attributable to the interference of Landlord, its agents or contractors with the completion of the Tenant Improvements; and (3) delay by Landlord in administering and paying when due the Tenant Allowance. In no event shall
Tenant’s remedies or entitlements for the occurrence of a Landlord Delay be abated, deferred, diminished or rendered inoperative because of a prior, concurrent, or subsequent delay resulting from any action or inaction of Tenant. No Landlord
Delay shall be deemed to have occurred unless and until Tenant has given written notice to Landlord specifying the action or inaction which Tenant contends constitutes a Landlord Delay. If such action or inaction is not cured within one
(1) business day after Landlord’s receipt of such notice, then a Landlord Delay, as set forth in such notice, shall be deemed to have occurred commencing as of the date Landlord received such notice and continuing for the number of days
the substantial completion of the Tenant Improvements was in fact delayed as a direct result of such action or inaction. 
  

	 	2.	Performance of the Tenant Improvements. 

 (a) Filing of Final Plans, Permits. Tenant, at its sole cost and expense, shall file the Final Plans with the governmental agencies having jurisdiction over the Tenant

  
 EXHIBIT B

 3 

 
Improvements. Tenant shall furnish Landlord with copies of all documents submitted to all such governmental agencies and with the authorizations to commence work and the permits for the Tenant
Improvements issued by such governmental agencies. Tenant shall not commence the Tenant Improvements until the required governmental authorizations for such work are obtained and delivered to Landlord. 

(b) Landlord Approval of Contractors. No later than five (5) days following Landlord’s approval of the Final Plans,
Tenant shall enter into a contract for construction of the Tenant Improvements with a general contractor acceptable to Landlord (the “General Contractor”). Landlord hereby approves of Skyline Construction as General Contractor, if
selected by Tenant. The General Contractor and Tenant’s construction contract with the General Contractor shall be subject to Landlord’s prior approval, which approval shall not be unreasonably withheld, conditioned or delayed. In the
event Landlord requires any of Tenant’s Contractors to obtain payment or performance bonds in connection with the installation of the Tenant Improvements, the cost of such bonds shall be the responsibility of Landlord and shall not be deducted
from the Tenant Allowance. The General Contractor shall be responsible for all required construction, management and supervision, including bidding by subcontractors for the various components of the work of the Tenant Improvements. In addition,
Tenant shall only utilize for purposes of mechanical, electrical, structural, sprinkler, fire and life safety and asbestos related activities those contractors as specifically designated by Landlord (collectively, the “Essential
Subs”). Tenant shall submit to Landlord not less than ten (10) days prior to commencement of construction the following information and items: 
 (i) The names and addresses of the other subcontractors, and sub- subcontractors (collectively, together with the General Contractor and Essential Subs, the “Tenant’s Contractors”)
Tenant intends to employ in the construction of the Tenant Improvements. Landlord shall have the right to approve or disapprove Tenant’s Contractors, and Tenant shall employ, as Tenant’s Contractors, only those persons or entities approved
by Landlord, which approval shall not be unreasonably withheld, conditioned or delayed (and failure to respond within ten (10) business days following delivery of a request for approval shall be deemed disapproval). All contractors and
subcontractors engaged by or on behalf of Tenant for the Expansion Space shall be licensed contractors, possessing good labor relations, capable of performing quality workmanship and working in harmony with Landlord’s contractors and
subcontractors and with other contractors and subcontractors on the job site. All work shall be coordinated with any general construction work in the Building. Tenant agrees to give the contractor employed by Landlord in the Building an equal
opportunity to submit a bid for the Tenant Improvements, but Tenant shall not be obligated to hire such contractor. 
 (ii) The
scheduled commencement date of construction, the estimated date of completion of construction work, fixturing work, and estimated date of occupancy of the Expansion Space by Tenant. 

(iii) Itemized statement of estimated construction cost, including permits and fees, architectural, engineering, and contracting fees.

 (iv) Certified copies of insurance policies or certificates of insurance as hereinafter described. Tenant shall not permit
Tenant’s Contractors to commence work until the 

  
 EXHIBIT B

 4 

 
required insurance has been obtained and certified copies of policies or certificates have been delivered to Landlord. 
 (c) Access to Expansion Space. Tenant, its employees, designers, contractors and workmen shall have access to and primary use of the Expansion Space to construct the Tenant Improvements, provided
that Tenant and its employees, agents, contractors, and suppliers only access the Expansion Space via the Building freight elevator work in harmony and do not interfere with the performance of other work in the Building by Landlord, Landlord’s
contractors, other tenants or occupants of the Building (whether or not the terms of their respective leases have commenced) or their contractors. If at any time such entry shall cause, or in Landlord’s reasonable judgment threaten to cause,
such disharmony or interference, Landlord may terminate such permission upon twenty-four (24) hours’ written notice to Tenant, and thereupon, Tenant or its employees, agents, contractors, and suppliers causing such disharmony or
interference shall immediately withdraw from the Expansion Space and the Building until Landlord determines such disturbance no longer exists. 
 (d) Landlord’s Right to Perform. Landlord shall have the right, but not the obligation, to perform, on behalf of and for the account of Tenant, subject to reimbursement by Tenant, any of the
Tenant Improvements which (i) Landlord reasonably deems necessary to be done on an emergency basis, (ii) pertains to structural components or the general Building systems, (iii) pertains to the erection of temporary safety barricades
or signs during construction, (iv) affects any asbestos-containing materials. Except in case of emergency, Landlord shall give prior reasonable written notice to Tenant of its intention to perform such work. 

(e) Warranties. On completion of the Tenant Improvements, Tenant shall provide Landlord with copies of all warranties of at least
one (1) year duration on all the Tenant Improvements. At Landlord’s request, Tenant shall enforce, at Tenant’s expense, all guarantees and warranties made and/or furnished to Tenant with respect to the Tenant Improvements. 

(f) Protection of Building. All work performed by Tenant shall be performed with a minimum of interference with other tenants and
occupants of the Building and shall conform to the Building Rules and Regulations attached as Exhibit “B,” to the Original Lease and those rules and regulations governing construction in the Building as Landlord or Landlord’s
Agent may impose. Tenant will take all reasonable and customary precautionary steps to protect its facilities and the facilities of others affected by the Tenant Improvements and to properly police same and Landlord shall have no responsibility for
any loss by theft or otherwise. Construction equipment and materials are to be located in confined areas and delivery and loading of equipment and materials shall be done at such reasonable locations and at such time as Landlord shall direct so as
not to burden the operation of the Building. Landlord shall advise Tenant in advance of any special delivery and loading dock requirements. Tenant shall at all times keep the Expansion Space and adjacent areas free from accumulations of waste
materials or rubbish caused by its suppliers, contractors or workmen. Landlord may require daily clean-up if required for fire prevention and life safety reasons or applicable laws and reserves the right to do clean-up at the expense of Tenant if
Tenant fails to comply with Landlord’s cleanup requirements. At the completion of the Tenant Improvements, Tenant’s Contractors shall forthwith remove all rubbish and all tools, equipment and surplus materials from and about the Expansion
Space and Building. Any damage caused by Tenant’s Contractors to any portion of 

  
 EXHIBIT B

 5 

 
the Building or to any property of Landlord or other tenants shall be repaired forthwith after written notice from Landlord to its condition prior to such damage by Tenant at Tenant’s
expense. 
 (g) Compliance by all Tenant Contractors. Tenant shall impose and enforce all terms hereof on Tenant’s
Contractors and its designers, architects and engineers. Landlord shall have the right to order Tenant or any of Tenant’s Contractors, designers, architects or engineers who willfully violate the provisions of this Workletter to cease work and
remove himself or itself and his or its equipment and employees from the Building. 
 (h) Accidents, Notice to Landlord.
Tenant’s Contractors shall assume responsibility for the prevention of accidents to its agents and employees and shall take all reasonable safety precautions with respect to the work to be performed and shall comply with all reasonable safety
measures initiated by the Landlord and with all applicable laws, ordinances, rules, regulations and orders of any public authority for the safety of persons or property. Tenant shall advise the Tenant’s Contractors to report to Landlord any
injury to any of its agents or employees and shall furnish Landlord a copy of the accident report filed with its insurance carrier within three (3) days of its occurrence. 

(i) Required Insurance. Tenant shall cause Tenant’s Contractors to secure, pay for, and maintain during the performance of
the construction of the Tenant Improvements, insurance in the following minimum coverages and limits of liability: 
 (i)
Workmen’s Compensation and Employer’s Liability Insurance as required by law. 
 (ii) Commercial General Liability
Insurance (including Owner’s and Contractors’ Protective Liability) in an amount not less than Two Million Dollars ($2,000,000) per occurrence, whether involving bodily injury liability (or death resulting therefrom) or property damage
liability or a combination thereof with a minimum aggregate limit of Two Million Dollars ($2,000,000), and with umbrella coverage with limits not less than Ten Million Dollars ($10,000,000). Such insurance shall provide for explosion and collapse,
completed operations coverage with a two-year extension after completion of the work, and broad form blanket contractual liability coverage and shall insure Tenant’s Contractors against any and all claims for bodily injury, including death
resulting therefrom and damage to the property of others and arising from its operations under the contracts whether such operations are performed by Tenant’s Contractors, or by anyone directly or indirectly employed by any of them. 

(iii) Comprehensive Automobile Liability Insurance, including the ownership, maintenance, and operation of any automotive equipment,
owned, hired, or non-owned in an amount not less than Five Hundred Thousand Dollars ($500,000) for each person in one accident, and One Million Dollars ($1,000,000) for injuries sustained by two or more persons in any one accident and property
damage liability in an amount not less than One Million Dollars ($1,000,000) for each accident. Such insurance shall insure Tenant’s Contractors against any and all claims for bodily injury, including death resulting therefrom, and damage to
the property of others arising from its operations under the contracts, whether such operations are performed by Tenant’s Contractors, or by anyone directly or indirectly employed by any of them. 

  
 EXHIBIT B

 6 

 (iv) “All-risk” builder’s risk insurance upon the entire Tenant Improvements
to the full insurance value thereof. Such insurance shall include the interest of Landlord and Tenant (and their respective contractors and subcontractors of any tier to the extent of any insurable interest therein) in the Tenant Improvements and
shall insure against the perils of fire and extended coverage and shall include “all-risk” builder’s risk insurance for physical loss or damage including, without duplication of coverage, theft, vandalism, and malicious mischief. If
portions of the Tenant Improvements are stored off the site of the Building or in transit to such site are not covered under such “all-risk” builder’s risk insurance, then Tenant shall effect and maintain similar property insurance on
such portions of the Tenant Improvements. Any loss insured under such “all-risk” builder’s risk insurance is to be adjusted with Landlord and Tenant and made payable to Landlord as trustee for the insureds, as their interest may
appear, subject to the agreement reached by such parties in interest, or in the absence of any such agreement, then in accordance with a final, nonappealable order of a court of competent jurisdiction. If after such loss no other special agreement
is made, the decision to replace or not replace any such damaged Tenant Improvements shall be made in accordance with the terms and provisions of the Amendment including, without limitation, this Workletter. The waiver of subrogation provisions
contained in Article 15 of the Original Lease shall apply to the “all-risk” builder’s risk insurance policy to be obtained by Tenant pursuant to this paragraph. 

All policies (except the workmen’s compensation policy) shall be endorsed to include as additional named insureds Landlord and its
officers, employees, and agents, Landlord’s contractors, Landlord’s architect, and such additional persons as Landlord may designate. Such endorsements shall also provide that all additional insured parties shall be given thirty
(30) days’ prior written notice of any reduction, cancellation, or nonrenewal of coverage by certified mail, return receipt requested (except that ten (10) days’ notice shall be sufficient in the case of cancellation for
nonpayment of premium) and shall provide that the insurance coverage afforded to the additional insured parties thereunder shall be primary to any insurance carried independently by such additional insured parties. Landlord shall furnish a list of
names and addresses of parties to be named as additional insureds. The insurance policies required hereunder shall be considered as the primary insurance and shall not call into contribution any insurance then maintained by Landlord. Additionally,
where applicable, such policy shall contain a cross-liability and severability or interest clause. 
 To the fullest extent
permitted by law, Tenant (and Tenant’s Contractors) and Landlord (and its contractors) shall indemnify and hold harmless the other party, its officers, agents and employees, from and against all claims, damages, liabilities, losses and expenses
of whatever nature, including but not limited to reasonable attorneys’ fees, the cost of any repairs to the Expansion Space or Building necessitated by activities of the indemnifying party’s contractors, bodily injury to persons or damage
to property of the indemnified party, its employees, agents, invitees, licensees, or others, arising out of or resulting from the performance of work by the indemnifying party or its contractors. The foregoing indemnity shall be in addition to the
insurance requirements set forth above and shall not be in discharge or substitution of the same, and shall not be limited in any way by any limitations on the amount or type of damages, compensation or benefits payable by or for Tenant’s
Contractors under Workers’ or Workmen’s Compensation Acts, Disability Benefit Acts or other Employee Benefit Acts. 

  
 EXHIBIT B

 7 

 (j) Quality of Work. The Tenant Improvements shall be constructed in a first-class
workmanlike manner using only good grades of material and in compliance with the Final Plans, all insurance requirements, applicable laws and ordinances and rules and regulations of governmental departments or agencies and the rules and regulations
adopted by Landlord for the Building. 
 (k) “As-Built” Plans. Upon completion of the Tenant Improvements,
Tenant shall furnish Landlord with “as built” plans for the Expansion Space, final waivers of lien for the Tenant Improvements, a detailed breakdown of the costs of the Tenant Improvements (which may be in the form of an owner’s
affidavit) and evidence of payment reasonably satisfactory to Landlord, and an occupancy permit for the Expansion Space. In addition, upon completion of the Tenant Improvements, Tenant will provide the Building’s architect a CAD file with the
construction floor plan showing partitions, doors, door swings and sidelights and such other information as the Building’s architect may require to allow the Building’s architect to update and maintain the “Space Utilization Data
Base.” Tenant shall pay the Building’s architect’s fee for this service. 
 (1) Mechanics’ Liens.
Tenant shall not permit any of the Tenant’s Contractors to place any lien upon the Building, and if any such lien is placed upon the Building, Tenant shall within ten (10) days of notice thereof, cause such lien to be discharged of record,
by bonding or otherwise. If Tenant shall fail to cause any such lien to be discharged, Landlord shall have the right to have such lien discharged and Landlord’s expense in so doing, including bond premiums, reasonable legal fees and filing
fees, shall be immediately due and payable by Tenant. 
  

	 	3.	Payment of Costs of the Tenant Improvements. 

 (a) Subject to the provisions of Paragraph 3(b) below, the Tenant Improvements (including the cost of acquiring and installing the Building Standard window blinds to the extent not in place) shall be
installed by Tenant at Tenant’s sole cost and expense. The cost of the Tenant Improvements shall include, and Tenant agrees to pay Landlord for, the following costs (“Landlord’s Costs”): (i) the cost of any work
performed by Landlord on behalf of Tenant and for any materials and labor furnished on Tenant’s behalf (it being understood that Tenant and Tenant’s Contractor are solely responsible for the installation of the Tenant Improvements),
(ii) all permit, design and engineering fees, all HVAC and sprinkler reconfiguration costs, and all life safety costs, (iii) the cost of any services provided to Tenant or Tenant’s Contractors including but not limited to the cost for
rubbish removal, hoisting, and utilities to the extent not included in general conditions charges by the general contractor, and (iv) the Supervision Fee plus Landlord’s actual out-of-pocket expenses for review of Tenant’s Proposed
Plans and Final Plans (subject to Section 1(b), above). Landlord may render bills to Tenant monthly for Landlord’s Costs (provided that the Supervision Fee shall be billed based on the cost of the Tenant Improvements performed during the
period in question). All bills shall be due and payable no later than the thirtieth (30th) day after delivery of such bills to Tenant, and Landlord may apply the Tenant Allowance against such Landlord’s Costs. Except as provided in
Section 3(b) below, the Tenant Allowance may not be applied against any costs associated with data cabling, telecommunication equipment installation, Tenant’s signage, or rent. The “Supervision Fee” shall be an amount
equal to three percent (3%) of the total cost of installation and construction of the Tenant Improvements. 

  
 EXHIBIT B

 8 

 (b) Landlord shall provide Tenant with an allowance of up to One Million One Hundred
Forty-One Thousand Forty and No/100 Dollars ($1,141,040.00) (“Tenant Allowance”) to be used toward payment of the costs incurred by Tenant for hard construction costs, permits, design and engineering fees, upgrades to the shell and
core, Building mechanical, plumbing, HVAC, electrical, structural, and fire life safety systems, and Landlord’s Costs in connection with the Tenant Improvements. Tenant may apply up to One Hundred Forty-Two Thousand Six Hundred Thirty and
No/100 Dollars ($142,630.00) of the Tenant Allowance for Tenant’s actual expenses for relocation/moving expenses, and data equipment and cabling installation in the Expansion Space. If Landlord reasonably anticipates that the Tenant Improvement
costs may exceed the Tenant Allowance (such excess shall be referred to herein as the “Over Allowance Amount”), and there is an Over-Allowance Amount required to be paid by Tenant pursuant to this Section for such disbursement,
Landlord shall only be required to make a disbursement equal to Landlord’s pro rata share thereof and simultaneously with each disbursement, Tenant will pay its pro rata share thereof. For purposes hereof, Landlord’s pro rata share for
each such disbursement amount shall equal the percentage resulting from dividing the Tenant Allowance by the total cost of the Tenant Improvement costs (as may be revised from time to time), and Tenant’s pro rata share for each such
disbursement amount shall equal the Over-Allowance Amount divided by such total cost of the Tenant Improvement costs. Landlord’s payment of such amounts shall not be deemed Landlord’s approval or acceptance of the work furnished or
materials supplied as set forth in Tenant’s draw request. If Landlord reasonably estimates that there will be an Over Allowance Amount payable by Tenant, then Tenant shall pay Tenant’s pro rata share (as described above) of the
Over-Allowance Amount directly to the Contractor during the construction of the Tenant Improvements as a condition precedent to Landlord’s obligation to disburse Landlord’s pro rata share of the Tenant Allowance. The Tenant Improvements
must be completed, and Tenant must have submitted its request for reimbursement in accordance with the terms of this Paragraph 3, no later than September 30, 2013. If the cost of all items of the Tenant Improvements is less than the Tenant
Allowance or if Tenant has not submitted its request for reimbursement for the entire Tenant Allowance in accordance with this Workletter by the foregoing deadline, Tenant shall not be entitled to any payment or credit for such excess or unused
amount. Funds may be drawn against the Tenant Allowance at any time and from time to time prior to September 30, 2013, subject to the following: 
 (i) Tenant may not make more than one draw in any calendar month; 
 (ii) With
each draw request, Tenant shall submit to Landlord the following documents: 
 (A) A true and correct copy of the application
for payment by Tenant’s Contractors for the Tenant Improvements completed to date, including sworn statements evidencing the cost of the Tenant Improvements performed to date (or in the case of subcontractors and materialmen, sworn statements
for the last preceding draw request) together with copies on all receipted bills and invoices; 
 (B) Conditional or final lien
waivers with respect to the Tenant Improvements performed to date from Tenant’s Contractors and any materialmen (or in the case 

  
 EXHIBIT B

 9 

 
of subcontractors and materialmen and except for the final disbursement of the Tenant Allowance, unconditional lien waivers for the last preceding draw request); 

(C) Tenant’s certification to Landlord that the amounts set forth in all contractor’s sworn statements are owed to
Tenant’s Contractors for the Tenant Improvements performed to date; 
 (D) The total cost of the Tenant Improvements based
on the Final Plans, as such cost may change from time to time; 
 (E) With the final draw request, Tenant shall submit to
Landlord a certificate from Tenant’s Architect stating that the Tenant Improvements has been completed in accordance with the Final Plans and applicable zoning, building, environmental and other laws and Unconditional Waiver and Release Upon
Progress Payment from the General Contractor and each of Tenant’s Contractors who have not theretofore delivered such unconditional waiver and release. 
 (iii) Landlord will disburse the portion of the Tenant Allowance allocable to each draw request to Tenant or at Tenant’s request or at Landlord’s option directly to Tenant’s Contractors
within thirty (30) days after Tenant has submitted the required information for such draw and has otherwise complied with the requirements hereof. 
 (c) Tenant shall pay for the Tenant Improvements and shall not permit the Expansion Space, Original Premises or Building or underlying property to become subject to any lien on account of labor, material,
or services furnished to Tenant. 
 (d) In the event Landlord wrongfully fails to disburse any amount of the Tenant Allowance as
required hereunder after Tenant has submitted all documents required hereunder with respect to such disbursement request and such failure continues for sixty (60) days after notice delivered to Landlord strictly in accordance with the
Amendment, Tenant shall have the right to (i) disburse such unpaid amounts to the General Contractor and (ii) offset such amounts against Base Rent next due and owing (up to an amount not to exceed 20% of the then scheduled Base Rent
amount in any month). 
  

	 	4.	Miscellaneous. 

 (a)
Tenant agrees that, in connection with the Tenant Improvements and its use of the Expansion Space prior to the Expansion Space Commencement Date, Tenant shall have those duties and obligations with respect thereto that it has pursuant to the Lease
during the Term, except the obligation for payment of rent, and further agrees that Landlord shall not be liable in any way for injury, loss, or damage which may occur to any of the Tenant Improvements or installations made in the Expansion Space,
or to any personal property placed therein, the same being at Tenant’s sole risk, except to the extent caused by the gross negligence or willful misconduct of Landlord or Landlord Parties. 

(b) Except as expressly set forth in the Amendment or the Lease, Landlord has no other agreement with Tenant and Landlord has no other
obligation to do any other work or pay any amounts with respect to the Expansion Space. Any other work in the Expansion 

  
 EXHIBIT B

 10 

 
Space which may be permitted by Landlord pursuant to the terms and conditions of the Amendment shall be done at Tenant’s sole cost and expense and in accordance with the terms and conditions
of the Lease. 
 (c) This Workletter shall not be deemed applicable to any additional space added to the Original Premises at
any time or from time to time, whether by any options under the Amendment or otherwise, or to any portion of the Original Premises or any additions thereto in the event of a renewal or extension of the initial term of the Lease, whether by any
options under the Lease or otherwise, unless expressly so provided in the Lease or any amendment or supplement thereto. 
 (d)
The failure by Tenant to pay any monies due to Landlord pursuant to this Workletter within five (5) business days after notice from Landlord to Tenant shall be deemed an Event of Default under the terms of the Lease for which Landlord shall be
entitled to exercise all remedies available to Landlord for nonpayment of Rent. All late payments shall bear interest pursuant to Section 18.04 of the Lease. 
 (e) Neither Landlord’s Agent nor the partners compromising Landlord or Landlord’s Agent, nor the shareholders (nor any of the partners comprising same), directors, officers, or shareholders of
any of the foregoing (collectively, the “Parties”) shall be liable for the performance of Landlord’s obligations under this Workletter. Tenant shall look solely to Landlord to enforce Landlord’s obligations hereunder and
shall not seek any damages against any of the Parties. The liability of Landlord for Landlord’s obligations under this Workletter shall not exceed and shall be limited to Landlord’s interest in the Building and Tenant shall not look to the
property or assets of any of the Parties in seeking either to enforce Landlord’s obligations under this Workletter or to satisfy a judgment for Landlord’s failure to perform such obligations. Upon a sale of the Building by Landlord, if the
buyer has assumed Landlord’s duties, obligations and liabilities hereunder, Tenant shall look solely to the buyer to enforce Tenant’s rights under this Workletter arising after the date of such sale. 

(f) Tenant shall be solely responsible to determine at the site all dimensions of the Expansion Space and the Building which affect any
work to be performed by Tenant hereunder. 

  
 EXHIBIT B

 11 

									
		 	LANDLORD:	 		 	 KNICKERBOCKER PROPERTIES, INC. XXXIII,
 a Delaware corporation

					
		 		 		 	By:	 	 /s/ Steven M. Zaun

		 		 		 		 	Steven M. Zaun
		 		 		 		 	Its: Vice President
				
		 	TENANT:	 		 	MEDIVATION, INC.,
		 		 		 	a Delaware corporation
					
		 		 		 	By:	 	 /s/ Patrick Machado

		 		 		 	Its:	 	 CFO & CBO

					
		 		 		 	By:	 	  

		 		 		 	Its:	 	  

  
 EXHIBIT B

 12 

 SCHEDULE “B-1” 

DESIGN STANDARDS 
  

	 	1.	HVAC 

 a. Outside summer:
79 degrees FDB 
 b. Inside summer: 74 degrees + or - 2.5 degrees FDB (shades drawn) 

c. Outside winter: 38 degrees FDB 
 d. Inside winter: 72 degrees FDB + or - 2.5 degrees FDB (shades drawn) 
 e.
Population Density: One occupant per 150 usable square feet. The greater of 15 cfm outside air per occupant or 0.15 cfm outside air per usable square foot in accordance with Title 24 of the California Code of Regulations 

 

	 	2.	Electrical 

 a. Subject to
Title 24 of the California Code of Regulations, 1.5 watts per usable square foot connected load/lighting/power — 480/277 volts 
 b. Subject to Title 24 of the California Code of Regulations, 3.5 watts per usable square foot connected load/miscellaneous power — 120/208 volts 

Total of 5 watts per usable square foot connected load 

  
 SCHEDULE B-1

 1Second Supplemental Indenture

 Exhibit 4.1B 
 SECOND SUPPLEMENTAL INDENTURE 
 SECOND SUPPLEMENTAL INDENTURE (this
“Supplemental Indenture”), dated as of September 19, 2012, among Appalachian Water Services, LLC, a Pennsylvania limited liability company (the “Guaranteeing Subsidiary”), an indirect subsidiary of Heckmann
Corporation, a Delaware corporation (the “Company”), the Company, the other Guarantors (as defined in the Indenture referred to herein) and The Bank of New York Mellon Trust Company, N.A., as trustee under the Indenture referred to
below (the “Trustee”). 
 W I T N E S S E T H 

WHEREAS, the Company has heretofore executed and delivered to the Trustee an indenture, dated as of April 10, 2012, as amended by
the First Supplemental Indenture, dated as of April 10, 2012 (as so amended, the “Indenture”), providing for the issuance of 9.875% Senior Notes due 2018 (the “Notes”); 

WHEREAS, the Indenture provides that under certain circumstances each Guaranteeing Subsidiary shall execute and deliver to the Trustee a
supplemental indenture pursuant to which such Guaranteeing Subsidiary shall unconditionally guarantee all of the Company’s Obligations under the Notes and the Indenture on the terms and conditions set forth herein (the “Note
Guarantee”); and 
 WHEREAS, pursuant to Section 9.01 of the Indenture, the Trustee is authorized to execute and
deliver this Supplemental Indenture; 
 NOW, THEREFORE, in consideration of the foregoing and for other good and valuable
consideration, the receipt of which is hereby acknowledged, the Guaranteeing Subsidiary and the Trustee mutually covenant and agree for the equal and ratable benefit of the Holders of the Notes as follows: 

1. CAPITALIZED TERMS. Capitalized terms used herein without definition shall have the meanings assigned to
them in the Indenture. 
 2. AGREEMENT TO GUARANTEE. The Guaranteeing Subsidiary
hereby agrees to provide an unconditional Guarantee on the terms and subject to the conditions set forth in the Note Guarantee and in the Indenture including but not limited to Article 10 thereof. 

4. NO RECOURSE AGAINST OTHERS. No director, officer, employee, incorporator
or stockholder of the Company or any Guarantor, as such, will have any liability for any obligations of the Company or the Guarantors under the Notes, this Indenture, the Note Guarantees or for any claim based on, in respect of, or by reason of,
such obligations or their creation. Each Holder of Notes by accepting a Note waives and releases all such liability. The waiver and release are part of the consideration for issuance of the Notes. The waiver may not be effective to waive liabilities
under the federal securities laws. 
 5. NEW YORK LAW TO GOVERN. THE INTERNAL LAW OF THE STATE OF NEW YORK SHALL GOVERN AND BE
USED TO CONSTRUE THIS SUPPLEMENTAL 

 
INDENTURE WITHOUT GIVING EFFECT TO APPLICABLE PRINCIPLES OF CONFLICTS OF LAW TO THE EXTENT THAT THE APPLICATION OF THE LAWS OF ANOTHER JURISDICTION WOULD BE REQUIRED THEREBY. 

6. COUNTERPARTS. The parties may sign any number of copies of this Supplemental Indenture. Each signed copy shall be an
original, but all of them together represent the same agreement. 
 7. EFFECT OF
HEADINGS. The Section headings herein are for convenience only and shall not affect the construction hereof. 

8. THE TRUSTEE. The Trustee shall not be responsible in any manner whatsoever for or in respect of the
validity or sufficiency of this Supplemental Indenture or for or in respect of the recitals contained herein, all of which recitals are made solely by the Guaranteeing Subsidiary and the Company. 

  
 - 2 -

 IN WITNESS WHEREOF, the parties hereto have caused this Supplemental Indenture to be duly
executed and attested, all as of the date first above written. 
  

					
	 APPALACHIAN WATER SERVICES, LLC, as Guaranteeing Subsidiary

		
	By:	 	 HEK WATER SOLUTIONS, LLC, its Managing Member

		
	By:	 	 /s/ Damian C. Georgino

		 	Name:	 	Damian C. Georgino
		 	Title:	 	Vice President
	
	 HECKMANN CORPORATION

		
	By:	 	 /s/ Damian C. Georgino

		 	Name:	 	Damian C. Georgino
		 	Title:	 	Executive Vice President, Corporate Development and Chief Legal Officer
	
	 HECKMANN WATER RESOURCES CORPORATION, as a Guarantor

		
	By:	 	 /s/ Damian C. Georgino

		 	Name:	 	Damian C. Georgino
		 	Title:	 	Vice President
	
	 HECKMANN WATER RESOURCES (CVR), INC., as a Guarantor

		
	By:	 	 /s/ Damian C. Georgino

		 	Name:	 	Damian C. Georgino
		 	Title:	 	Vice President

 [Signature page to Second Supplemental Indenture] 

 
					
	 1960 WELL SERVICES, LLC, as a Guarantor

		
	By:	 	 /s/ Damian C. Georgino

		 	Name:	 	Damian C. Georgino
		 	Title:	 	Vice President
	
	 HEK WATER SOLUTIONS, as a Guarantor

		
	By:	 	 /s/ Damian C. Georgino

		 	Name:	 	Damian C. Georgino
		 	Title:	 	Vice President
	
	 HECKMANN HYDROCARBONS HOLDINGS CORPORATION, as a Guarantor

		
	By:	 	 /s/ Damian C. Georgino

		 	Name:	 	Damian C. Georgino
		 	Title:	 	Vice President
	
	 TFI HOLDINGS, INC., as a Guarantor

		
	By:	 	 /s/ Damian C. Georgino

		 	Name:	 	Damian C. Georgino
		 	Title:	 	Vice President
	
	 THERMO FLUIDS INC., as a Guarantor

		
	By:	 	 /s/ Damian C. Georgino

		 	Name:	 	Damian C. Georgino
		 	Title:	 	Vice President
	
	 THE BANK OF NEW YORK MELLON TRUST COMPANY, N.A., as Trustee

		
	By:	 	 /s/ Lawrence M. Kusch

		 	Name:	 	Lawrence M. Kusch
		 	Title:	 	Vice President

 [Signature page to Second Supplemental Indenture]

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00209-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00209-of-00352.parquet"}]]