Document:

exv10w28

 

Exhibit 10.28

(Local Currency3⁄4Single Jurisdiction)

International Swap Dealers Association, Inc.

MASTER AGREEMENT

Dated as of : 12/19/2006

	 	 	 	 	 
	First National Bank of Omaha
	 	and
	 	Cardinal Ethanol, LLC

have entered and/or anticipate entering into one or more transactions (each a “Transaction”) that
are or will be governed by this Master Agreement, which includes the schedule (the “Schedule”), and
the documents and other confirming evidence (each a “Confirmation”) exchanged between the parties
confirming those Transactions.

Accordingly, the parties agree as follows:3⁄4

1. Interpretation

(a) Definitions. The terms defined in Section 12 and in the Schedule will have the meanings therein
specified for the purpose of this Master Agreement.

(b) Inconsistency. In the event of any inconsistency between the provisions of the Schedule and the
other provisions of this Master Agreement, the Schedule will prevail. In the event of any
inconsistency between the provisions of any Confirmation and this Master Agreement (including the
Schedule), such Confirmation will prevail for the purpose of the relevant Transaction.

(c) Single Agreement. All Transactions are entered into in reliance on the fact that this Master
Agreement and all Confirmations form a single agreement between the parties (collectively referred
to as this “Agreement”), and the parties would not otherwise enter into any Transactions.

2. Obligations

(a) General Conditions.

(i) Each party will make each payment or delivery specified in each Confirmation to be made
by it, subject to the other provisions of this Agreement.

(ii) Payments under this Agreement will be made on the due date for value on that date in
the place of the account specified in the relevant Confirmation or otherwise pursuant to
this Agreement, in freely transferable funds and in the manner customary for payments in the
required currency. Where settlement is by delivery (that is, other than by payment), such
delivery will be made for receipt on the due date in the manner customary for the relevant
obligation unless otherwise specified in the relevant Confirmation or elsewhere in this
Agreement.

(iii) Each obligation of each party under Section 2(a)(i) is subject to (1) the condition
precedent that no Event of Default or Potential Event of Default with respect to the other
party has occurred and is continuing, (2) the condition precedent that no Early Termination
Date in respect of the relevant Transaction has occurred or been effectively designated and
(3) each other applicable condition precedent specified in this Agreement.

Copyright
® 1992 by International Swap Dealers Association, Inc.

Second
Printing

 

 

b) Change of Account. Either party may change its account for receiving a payment or delivery by
giving notice to the other party at least five Local Business Days prior to the scheduled date for
the payment or delivery to which such change applies unless such other party gives timely notice of
a reasonable objection to such change.

(c) Netting. If on any date amounts would otherwise be payable:—

	 	(i)	 	in the same currency; and
	 
	 	(ii)	 	in respect of the same Transaction

by each party to the other, then, on such date, each party’s obligation to make payment of any such
amount will be automatically satisfied and discharged and, if the aggregate amount that would
otherwise have been payable by one party exceeds the aggregate amount that would otherwise have
been payable by the other party, replaced by an obligation upon the party by whom the larger
aggregate amount would have been payable to pay to the other party the excess of the larger
aggregate amount over the smaller aggregate amount.

The parties may elect in respect of two or more Transactions that a net amount will be determined
in respect of all amounts payable on the same date in the same currency in respect of such
Transactions, regardless of whether such amounts are payable in respect of the same Transaction.
The election may be made in the Schedule or a Confirmation by specifying that subparagraph (ii)
above will not apply to the Transactions identified as being subject to the election, together with
the starting date (in which case subparagraph (ii) above will not, or will cease to, apply to such
Transactions from such date). This election may be made separately for different groups of
Transactions and will apply separately to each pairing of branches or offices through which the
parties make and receive payments or deliveries.

(d) Default Interest; Other Amounts. Prior to the occurrence or effective designation of an Early
Termination Date in respect of the relevant Transaction, a party that defaults in the performance
of any payment obligation will, to the extent permitted by law and subject to Section 6(c), be
required to pay interest (before as well as after judgment) on the overdue amount to the other
party on demand in the same currency as such overdue amount, for the period from (and including)
the original due date for payment to (but excluding) the date of actual payment, at the Default
Rate. Such interest will be calculated on the basis of daily compounding and the actual number of
days elapsed. If, prior to the occurrence or effective designation of an Early Termination Date in
respect of the relevant Transaction, a party defaults in the performance of any obligation required
to be settled by delivery, it will compensate the other party on demand if and to the extent
provided for in the relevant Confirmation or elsewhere in this Agreement.

3. Representations

Each party represents to the other party (which representations will be deemed to be repeated by
each party on each date on which a Transaction is entered into) that:—

(a) Basic Representations.

(i) Status. It is duly organised and validly existing under the laws of the jurisdiction of
its organisation or incorporation and, if relevant under such laws, in good standing;

(ii) Powers. It has the power to execute this Agreement and any other documentation
relating to this Agreement to which it is a party, to deliver this Agreement and any other
documentation relating to this Agreement that it is required by this Agreement to deliver
and to perform its obligations under this Agreement and any obligations it has under any
Credit Support Document to which it is a party and has taken all necessary action to
authorise such execution, delivery and performance;

(iii) No Violation or Conflict. Such execution, delivery and performance do not violate or
conflict with any law applicable to it, any provision of its constitutional documents, any
order or judgment of any court or other agency of government applicable to it or any of its
assets or any contractual restriction binding on or affecting it or any of its assets;

2

Second
Printing

 

(iv) Consents. All governmental and other consents that are required to have been obtained
by it with respect to this Agreement or any Credit Support Document to which it is a party
have been obtained and are in full force and effect and all conditions of any such consents
have been complied with; and

(v) Obligations Binding. Its obligations under this Agreement and any Credit Support
Document to which it is a party constitute its legal, valid and binding obligations,
enforceable in accordance with their respective terms (subject to applicable bankruptcy,
reorganisation, insolvency, moratorium or similar laws affecting creditors’ rights generally
and subject, as to enforceability, to equitable principles of general application
(regardless of whether enforcement is sought in a proceeding in equity or at law)).

(b) Absence of Certain Events. No Event of Default or Potential Event of Default or, to its
knowledge, Termination Event with respect to it has occurred and is continuing and no such event or
circumstance would occur as a result of its entering into or performing its obligations under this
Agreement or any Credit Support Document to which it is a party.

(c) Absence of Litigation. There is not pending or, to its knowledge, threatened against it or any
of its Affiliates any action, suit or proceeding at law or in equity or before any court, tribunal,
governmental body, agency or official or any arbitrator that is likely to affect the legality,
validity or enforceability against it of this Agreement or any Credit Support Document to which it
is a party or its ability to perform its obligations under this Agreement or such Credit Support
Document.

(d) Accuracy of Specified Information. All applicable information that is furnished in writing by
or on behalf of it to the other party and is identified for the purpose of this Section 3(d) in the
Schedule is, as of the date of the information, true, accurate and complete in every material
respect.

4. Agreements

Each party agrees with the other that, so long as either party has or may have any obligation under
this Agreement or under any Credit Support Document to which it is a party:—

(a) Furnish Specified Information. It will deliver to the other party any forms, documents or
certificates specified in the Schedule or any Confirmation by the date specified in the Schedule or
such Confirmation or, if none is specified, as soon as reasonably practicable.

(b) Maintain Authorisations. It will use all reasonable efforts to maintain in full force and
effect all consents of any governmental or other authority that are required to be obtained by it
with respect to this Agreement or any Credit Support Document to which it is a party and will use
all reasonable efforts to obtain any that may become necessary in the future.

(c) Comply with Laws. It will comply in all material respects with all applicable laws and orders
to which it may be subject if failure so to comply would materially impair its ability to perform
its obligations under this Agreement or any Credit Support Document to which it is a party.

5. Events of Default and Termination Events

(a) Events of Default. The occurrence at any time with respect to a party or, if applicable, any
Credit Support Provider of such party or any Specified Entity of such party of any of the following
events constitutes an event of default (an “Event of Default”) with respect to such party:—

(i) Failure to Pay or Deliver. Failure by the party to make, when due, any payment under
this Agreement or delivery under Section 2(a)(i) or 2(d) required to be made by it if such
failure is not remedied on or before the third Local Business Day after notice of such
failure is given to the party;

     (ii) Breach of Agreement. Failure by the party to comply with or perform any agreement or
obligation (other than an obligation to make any payment under this Agreement or delivery
under Section 2(a)(i) or 2(d) or to give notice of a Termination Event) to be complied with
or performed

3

Second
Printing

 

by the party in accordance with this Agreement if such failure is not remedied on or before
the thirtieth day after notice of such failure is given to the party;

(iii) Credit Support Default.

(1) Failure by the party or any Credit Support Provider of such party to comply
with or perform any agreement or obligation to be complied with or performed by
it in accordance with any Credit Support Document if such failure is continuing
after any applicable grace period has elapsed;

(2) the expiration or termination of such Credit Support Document or the failing
or ceasing of such Credit Support Document to be in full force and effect for the
purpose of this Agreement (in either case other than in accordance with its
terms) prior to the satisfaction of all obligations of such party under each
Transaction to which such Credit Support Document relates without the written
consent of the other party; or

(3) the party or such Credit Support Provider disaffirms, disclaims, repudiates
or rejects, in whole or in part, or challenges the validity of, such Credit
Support Document;

(iv) Misrepresentation. A representation made or repeated or deemed to have been made or
repeated by the party or any Credit Support Provider of such party in this Agreement or any
Credit Support Document proves to have been incorrect or misleading in any material respect
when made or repeated or deemed to have been made or repeated;

(v) Default under Specified Transaction. The party, any Credit Support Provider of such
party or any applicable Specified Entity of such party (1) defaults under a Specified
Transaction and, after giving effect to any applicable notice requirement or grace period,
there occurs a liquidation of, an acceleration of obligations under, or an early termination
of, that Specified Transaction, (2) defaults, after giving effect to any applicable notice
requirement or grace period, in making any payment or delivery due on the last payment,
delivery or exchange date of, or any payment on early termination of, a Specified
Transaction (or such default continues for at least three Local Business Days if there is no
applicable notice requirement or grace period) or (3) disaffirms, disclaims, repudiates or
rejects, in whole or in part, a Specified Transaction (or such action is taken by any person
or entity appointed or empowered to operate it or act on its behalf);

(vi) Cross Default. If “Cross Default” is specified in the Schedule as applying to the
party, the occurrence or existence of (1) a default, event of default or other similar
condition or event (however described) in respect of such party, any Credit Support Provider
of such party or any applicable Specified Entity of such party under one or more agreements
or instruments relating to Specified Indebtedness of any of them (individually or
collectively) in an aggregate amount of not less than the applicable Threshold Amount (as
specified in the Schedule) which has resulted in such Specified Indebtedness becoming, or
becoming capable at such time of being declared, due and payable under such agreements or
instruments, before it would otherwise have been due and payable or (2) a default by such
party, such Credit Support Provider or such Specified Entity (individually or collectively)
in making one or more payments on the due date thereof in an aggregate amount of not less
than the applicable Threshold Amount under such agreements or instruments (after giving
effect to any applicable notice requirement or grace period);

(vii) Bankruptcy. The party, any Credit Support Provider of such party or any applicable
Specified Entity of such party:—

(1) is dissolved (other than pursuant to a consolidation, amalgamation or merger);
(2) becomes insolvent or is unable to pay its debts or fails or admits in writing
its inability generally to pay its debts as they become due; (3) makes a general
assignment, arrangement or composition with or for the benefit of its creditors; (4)
institutes or has instituted against it a proceeding seeking a judgment of
insolvency or bankruptcy or any other relief under any bankruptcy or insolvency law
or other similar law affecting creditors’ rights, or a petition is presented for its
winding-up or liquidation, and, in the case of any such proceeding or petition
instituted or presented against it, such proceeding or petition (A) results in a
judgment of insolvency or bankruptcy or the entry of an order for relief or

4

Second
Printing

 

the making of an order for its winding-up or liquidation or (B) is not dismissed,
discharged, stayed or restrained in each case within 30 days of the institution or
presentation thereof; (5) has a resolution passed for its winding-up, official
management or liquidation (other than pursuant to a consolidation, amalgamation or
merger); (6) seeks or becomes subject to the appointment of an administrator,
provisional liquidator, conservator, receiver, trustee, custodian or other similar
official for it or for all or substantially all its assets; (7) has a secured party
take possession of all or substantially all its assets or has a distress, execution,
attachment, sequestration or other legal process levied, enforced or sued on or
against all or substantially all its assets and such secured party maintains
possession, or any such process is not dismissed, discharged, stayed or restrained,
in each case within 30 days thereafter; (8) causes or is subject to any event with
respect to it which, under the applicable laws of any jurisdiction, has an analogous
effect to any of the events specified in clauses (1) to (7) (inclusive); or (9)
takes any action in furtherance of, or indicating its consent to, approval of, or
acquiescence in, any of the foregoing acts; or

(viii) Merger Without Assumption. The party or any Credit Support Provider of such party
consolidates or amalgamates with, or merges with or into, or transfers all or substantially
all its assets to, another entity and, at the time of such consolidation, amalgamation,
merger or transfer:—

(1) the resulting, surviving or transferee entity fails to assume all the
obligations of such party or such Credit Support Provider under this Agreement or
any Credit Support Document to which it or its predecessor was a party by operation
of law or pursuant to an agreement reasonably satisfactory to the other party to
this Agreement; or

(2) the benefits of any Credit Support Document fail to extend (without the consent
of the other party) to the performance by such resulting, surviving or transferee
entity of its obligations under this Agreement.

(b) Termination Events. The occurrence at any time with respect to a party or, if applicable, any
Credit Support Provider of such party or any Specified Entity of such party of any event specified
below constitutes an Illegality if the event is specified in (i) below, and, if specified to be
applicable, a Credit Event Upon Merger if the event is specified pursuant to (ii) below or an
Additional Termination Event if the event is specified pursuant to (iii) below:—

(i) Illegality. Due to the adoption of, or any change in, any applicable law after the date
on which a Transaction is entered into, or due to the promulgation of, or any change in, the
interpretation by any court, tribunal or regulatory authority with competent jurisdiction of
any applicable law after such date, it becomes unlawful (other than as a result of a breach
by the party of Section 4(b)) for such party (which will be the Affected Party):—

(1) to perform any absolute or contingent obligation to make a payment or delivery
or to receive a payment or delivery in respect of such Transaction or to comply with
any other material provision of this Agreement relating to such Transaction; or

(2) to perform, or for any Credit Support Provider of such party to perform, any
contingent or other obligation which the party (or such Credit Support Provider) has
under any Credit Support Document relating to such Transaction;

(ii) Credit Event Upon Merger. If “Credit Event Upon Merger” is specified in the Schedule
as applying to the party, such party (“X”), any Credit Support Provider of X or any
applicable Specified Entity of X consolidates or amalgamates with, or merges with or into,
or transfers all or substantially all its assets to, another entity and such action does not
constitute an event described in Section 5(a)(viii) but the creditworthiness of the
resulting, surviving or transferee entity is materially weaker than that of X, such Credit
Support Provider or such Specified Entity, as the case may be, immediately prior to such
action (and, in such event, X or its successor or transferee, as appropriate, will be the
Affected Party); or

(iii) Additional Termination Event. If any “Additional Termination Event” is specified in
the Schedule or any Confirmation as applying, the occurrence of such event (and, in such
event, the

5

Second
Printing

 

Affected Party or Affected Parties shall be as specified for such Additional Termination
Event in the Schedule or such Confirmation).

(c) Event of Default and Illegality. If an event or circumstance which would otherwise constitute
or give rise to an Event of Default also constitutes an Illegality, it will be treated as an
Illegality and will not constitute an Event of Default.

6. Early Termination

(a) Right to Terminate Following Event of Default. If at any time an Event of Default with respect
to a party (the “Defaulting Party”) has occurred and is then continuing, the other party (the
“Non-defaulting Party”) may, by not more than 20 days notice to the Defaulting Party specifying the
relevant Event of Default, designate a day not earlier than the day such notice is effective as an
Early Termination Date in respect of all outstanding Transactions. If, however, “Automatic Early
Termination” is specified in the Schedule as applying to a party, then an Early Termination Date in
respect of all outstanding Transactions will occur immediately upon the occurrence with respect to
such party of an Event of Default specified in Section 5 (a)(vii)(1), (3), (5), (6) or, to the
extent analogous thereto, (8), and as of the time immediately preceding the institution of the
relevant proceeding or the presentation of the relevant petition upon the occurrence with respect
to such party of an Event of Default specified in Section 5(a)(vii)(4) or, to the extent analogous
thereto, (8).

(b) Right to Terminate Following Termination Event.

(i) Notice. If a Termination Event occurs, an Affected Party will, promptly upon becoming
aware of it, notify the other party, specifying the nature of that Termination Event and
each Affected Transaction and will also give such other information about that Termination
Event as the other party may reasonably require.

(ii) Two Affected Parties. If an Illegality under Section 5(b)(i)(1) occurs and there are
two Affected Parties, each party will use all reasonable efforts to reach agreement within
30 days after notice thereof is given under Section 6(b)(i) on action to avoid that
Termination Event.

(iii) Right to Terminate. If:—

(1) an agreement under Section 6(b)(ii) has not been effected with respect to all
Affected Transactions within 30 days after an Affected Party gives notice under
Section 6(b)(i); or

(2) an Illegality other than that referred to in Section 6(b)(ii), a Credit Event
Upon Merger or an Additional Termination Event occurs,

either party in the case of an Illegality, any Affected Party in the case of an Additional
Termination Event if there is more than one Affected Party, or the party which is not the
Affected Party in the case of a Credit Event Upon Merger or an Additional Termination Event
if there is only one Affected Party may, by not more than 20 days notice to the other party
and provided that the relevant Termination Event is then continuing, designate a day not
earlier than the day such notice is effective as an Early Termination Date in respect of all
Affected Transactions.

(c) Effect of Designation.

(i) If notice designating an Early Termination Date is given under Section 6(a) or (b), the
Early Termination Date will occur on the date so designated, whether or not the relevant
Event of Default or Termination Event is then continuing.

(ii) Upon the occurrence or effective designation of an Early Termination Date, no further
payments or deliveries under Section 2(a)(i) or 2(d) in respect of the Terminated
Transactions will be required to be made, but without prejudice to the other provisions of
this Agreement. The amount, if any, payable in respect of an Early Termination Date shall
be determined pursuant to Section 6(e).

(d) Calculations.

6

Second
Printing

 

(i) Statement. On or as soon as reasonably practicable following the occurrence of an Early
Termination Date, each party will make the calculations on its part, if any, contemplated by
Section 6(e) and will provide to the other party a statement (1) showing, in reasonable
detail, such calculations (including all relevant quotations and specifying any amount
payable under Section 6(e)) and (2) giving details of the relevant account to which any
amount payable to it is to be paid. In the absence of written confirmation from the source
of a quotation obtained in determining a Market Quotation, the records of the party
obtaining such quotation will be conclusive evidence of the existence and accuracy of such
quotation.

(ii) Payment Date. An amount calculated as being due in respect of any Early Termination
Date under Section 6(e) will be payable on the day that notice of the amount payable is
effective (in the case of an Early Termination Date which is designated or occurs as a
result of an Event of Default) and on the day which is two Local Business Days after the day
on which notice of the amount payable is effective (in the case of an Early Termination Date
which is designated as a result of a Termination Event). Such amount will be paid together
with (to the extent permitted under applicable law) interest thereon (before as well as
after judgment), from (and including) the relevant Early Termination Date to (but excluding)
the date such amount is paid, at the Applicable Rate. Such interest will be calculated on
the basis of daily compounding and the actual number of days elapsed.

(e) Payments on Early Termination. If an Early Termination Date occurs, the following provisions
shall apply based on the parties’ election in the Schedule of a payment measure, either “Market
Quotation” or “Loss”, and a payment method, either the “First Method” or the “Second Method”. If
the parties fail to designate a payment measure or payment method in the Schedule, it will be
deemed that “Market Quotation” or the “Second Method”, as the case may be, shall apply. The
amount, if any, payable in respect of an Early Termination Date and determined pursuant to this
Section will be subject to any Set-off.

(i) Events of Default. If the Early Termination results from an Event of Default:—

(1) First Method and Market Quotation. If the First Method and Market Quotation
apply, the Defaulting Party will pay to the Non-defaulting Party the excess, if a
positive number, of (A) the sum of the Settlement Amount (determined by the
Non-defaulting Party) in respect of the Terminated Transactions and the Unpaid
Amounts owing to the Non-defaulting Party over (B) the Unpaid Amounts owing to the
Defaulting Party.

(2) First Method and Loss. If the First Method and Loss apply, the Defaulting Party
will pay to the Non-defaulting Party, if a positive number, the Non-defaulting
Party’s Loss in respect of this Agreement.

(3) Second Method and Market Quotation. If the Second Method and Market Quotation
apply, an amount will be payable equal to (A) the sum of the Settlement Amount
(determined by the Non-defaulting Party) in respect of the Terminated Transactions
and the Unpaid Amounts owing to the Non-defaulting Party less (B) the Unpaid Amounts
owing to the Defaulting Party. If that amount is a positive number, the Defaulting
Party will pay it to the Non-defaulting party; if it is a negative number, the
Non-defaulting Party will pay the absolute value of that amount to the Defaulting
Party.

(4) Second Method and Loss. If the Second Method and Loss apply, an amount will be
payable equal to the Non-defaulting Party’s Loss in respect of this Agreement. If
that amount is a positive number, the Defaulting Party will pay it to the
Non-defaulting Party; if it is a negative number, the Non-defaulting Party will pay
the absolute value of that amount to the Defaulting Party.

(ii) Termination Events. If the Early Termination Date results from a Termination Event:—

(1) One Affected Party. If there is one Affected Party, the amount payable will be
determined in accordance with Section 6(e)(i)(3), if Market Quotation applies, or
Section 6(e)(i)(4), if Loss applies, except that, in either case, references to the
Defaulting Party and to the Non-defaulting Party will be deemed to be references to
the Affected Party and the party which is not the Affected Party, respectively, and,
if Loss applies and fewer than

7

Second
Printing

 

all the Transactions are being terminated, Loss shall be calculated in respect of
all Terminated Transactions.

(2) Two Affected Parties. If there are two Affected Parties: —

(A) If Market Quotation applies, each party will determine a Settlement
Amount in respect of the Terminated Transactions, and an amount will be
payable equal to (I) the sum of (a) one-half of the difference between the
Settlement Amount of the party with the higher Settlement Amount (“X”) and
the Settlement Amount of the party with the lower Settlement Amount (“Y”)
and (b) the Unpaid Amounts owing to X less (II) the Unpaid Amounts owing to
Y; and

(B) If Loss applies, each party will determine its Loss in respect of this
Agreement (or, if fewer than all the Transactions are being terminated, in
respect of all Terminated Transactions) and an amount will be payable equal
to one-half of the difference between the Loss of the party with the higher
Loss (“X”) and the Loss of the party with the lower Loss (“Y”).

If the amount payable is a positive number, Y will pay it to X; if it is a negative
number, X will pay the absolute value of that amount to Y.

(iii) Adjustment for Bankruptcy. In circumstances where an Early Termination Date
occurs because “Automatic Early Termination” applies in respect of a party, the
amount determined under this Section 6(e) will be subject to such adjustments as are
appropriate and permitted by law to reflect any payments or deliveries made by one
party to the other under this Agreement (and retained by such other party) during
the period from the relevant Early Termination Date to the date for payment
determined under Section 6(d)(ii).

(iv) Pre-Estimate. The parties agree that if Market Quotation applies an amount
recoverable under this Section 6(e) is a reasonable pre-estimate of loss and not a
penalty. Such amount is payable for the loss of bargain and the loss of protection
against future risks and except as otherwise provided in this Agreement neither
party will be entitled to recover any additional damages as a consequence of such
losses.

8

Second
Printing

 

7. Transfer

Neither this Agreement nor any interest or obligation in or under this Agreement may be transferred
(whether by way of security or otherwise) by either party without the prior written consent of the
other party, except that: —

(a) a party may make such a transfer of this Agreement pursuant to a consolidation or amalgamation
with, or merger with or into, or transfer of all or substantially all its assets to, another entity
(but without prejudice to any other right or remedy under this Agreement); and

(b) a party may make such a transfer of all or any part of its interest in any amount payable to it
from a Defaulting Party under Section 6(e).

Any purported transfer that is not in compliance with this Section will be void.

8. Miscellaneous

(a) Entire Agreement. This Agreement constitutes the entire agreement and understanding of the
parties with respect to its subject matter and supersedes all oral communication and prior writings
with respect thereto.

(b) Amendments. No amendment, modification or waiver in respect of this Agreement will be
effective unless in writing (including a writing evidenced by a facsimile transmission) and
executed by each of the parties or confirmed by an exchange of telexes or electronic messages on an
electronic messaging system.

(c) Survival of Obligations. Without prejudice to Sections 2(a)(iii) and 6(c)(ii), the obligations
of the parties under this Agreement will survive the termination of any Transaction.

(d) Remedies Cumulative. Except as provided in this Agreement, the rights, powers, remedies and
privileges provided in this Agreement are cumulative and not exclusive of any rights, powers,
remedies and privileges provided by law.

(e) Counterparts and Confirmations.

(i) This Agreement (and each amendment, modification and waiver in respect of it) may be
executed and delivered in counterparts (including by facsimile transmission), each of which
will be deemed an original.

(ii) The parties intend that they are legally bound by the terms of each Transaction from
the moment they agree to those terms (whether orally or otherwise). A Confirmation shall be
entered into as soon as practicable and may be executed and delivered in counterparts
(including by facsimile transmission) or be created by an exchange of telexes or by an
exchange of electronic messages on an electronic messaging system, which in each case will
be sufficient for all purposes to evidence a binding supplement to this Agreement. The
parties will specify therein or through another effective means that any such counterpart,
telex or electronic message constitutes a Confirmation.

(f) No Waiver of Rights. A failure or delay in exercising any right, power or privilege in respect
of this Agreement will not be presumed to operate as a waiver, and a single or partial exercise of
any right, power or privilege will not be presumed to preclude any subsequent or further exercise,
of that right, power or privilege or the exercise of any other right, power or privilege.

(g) Headings. The headings used in this Agreement are for convenience of reference only and are
not to affect the construction of or to be taken into consideration in interpreting this Agreement.

9. Expenses

A Defaulting Party will, on demand, indemnify and hold harmless the other party for and against all
reasonable out-of-pocket expenses, including legal fees, incurred by such other party by reason of
the enforcement and protection of its rights under this Agreement or any Credit Support Document to
which

9

Second
Printing

 

the Defaulting Party is a party or by reason of the early termination of any Transaction,
including, but not limited to, costs of collection.

10. Notices

(a) Effectiveness. Any notice or other communication in respect of this Agreement may be given in
any manner set forth below (except that a notice or other communication under Section 5 or 6 may
not be given by facsimile transmission or electronic messaging system) to the address or number or
in accordance with the electronic messaging system details provided (see the Schedule) and will be
deemed effective as indicated:—

(i) if in writing and delivered in person or by courier, on the date it is delivered;

(ii) if sent by telex, on the date the recipient’s answerback is received;

(iii) if sent by facsimile transmission, on the date that transmission is received by a
responsible employee of the recipient in legible form (it being agreed that the burden of
proving receipt will be on the sender and will not be met by a transmission report generated
by the sender’s facsimile machine);

(iv) if sent by certified or registered mail (airmail, if overseas) or the equivalent
(return receipt requested), on the date that mail is delivered or its delivery is attempted;
or

(v) if sent by electronic messaging system, on the date that electronic message is received,

unless the date of that delivery (or attempted delivery) or that receipt, as applicable, is not a
Local Business Day or that communication is delivered (or attempted) or received, as applicable,
after the close of business on a Local Business Day, in which case that communication shall be
deemed given and effective on the first following day that is a Local Business Day.

(b) Change of Addresses. Either party may by notice to the other change the address, telex or
facsimile number or electronic messaging system details at which notices or other communications
are to be given to it.

11. Governing Law and Jurisdiction

(a) Governing Law. This Agreement will be governed by and construed in accordance with the law
specified in the Schedule.

(b) Jurisdiction. With respect to any suit, action or proceedings relating to this Agreement
(“Proceedings”), each party irrevocably:—

(i) submits to the jurisdiction of the English courts, if this Agreement is expressed to be
governed by English law, or to the non-exclusive jurisdiction of the courts of the State of
New York and the United States District Court located in the Borough of Manhattan in New
York City, if this Agreement is expressed to be governed by the laws of the State of New
York; and

(ii) waives any objection which it may have at any time to the laying of venue of any
Proceedings brought in any such court, waives any claim that such Proceedings have been
brought in an inconvenient forum and further waives the right to object, with respect to
such Proceedings, that such court does not have any jurisdiction over such party.

Nothing in this Agreement precludes either party from bringing Proceedings in any other
jurisdiction (outside, if this Agreement is expressed to be governed by English law, the
Contracting States, as defined in Section 1(3) of the Civil Jurisdiction and Judgments Act 1982 or
any modification, extension or re-enactment thereof for the time being in force) nor will the
bringing of Proceedings in any one or more jurisdictions preclude the bringing of Proceedings in
any other jurisdiction.

(c) Waiver of Immunities. Each party irrevocably waives, to the fullest extent permitted by
applicable law, with respect to itself and its revenues and assets (irrespective of their use or
intended use), all immunity on the grounds of sovereignty or other similar grounds from (i) suit,
(ii) jurisdiction of

10

Second
Printing

 

any court, (iii) relief by way of injunction, order for specific performance or for recovery of
property, (iv) attachment of its assets (whether before or after judgment) and (v) execution or
enforcement of any judgment to which it or its revenues or assets might otherwise be entitled in
any Proceedings in the courts of any jurisdiction and irrevocably agrees, to the extent permitted
by applicable law, that it will not claim any such immunity in any Proceedings.

12. Definitions

As used in this Agreement:—

“Additional Termination Event” has the meaning specified in Section 5(b).

“Affected Party” has the meaning specified in Section 5(b).

“Affected Transactions” means (a) with respect to any Termination Event consisting of an
Illegality, all Transactions affected by the occurrence of such Termination Event and (b) with
respect to any other Termination Event, all Transactions.

“Affiliate” means, subject to the Schedule, in relation to any person, any entity controlled,
directly or indirectly, by the person, any entity that controls, directly or indirectly, the person
or any entity directly or indirectly under common control with the person. For this purpose,
“control” of any entity or person means ownership of a majority of the voting power of the entity
or person.

“Applicable Rate” means:—

(a) in respect of obligations payable or deliverable (or which would have been but for Section
2(a)(iii)) by a Defaulting Party, the Default Rate;

(b) in respect of an obligation to pay an amount under Section 6(e) of either party from and after
the date (determined in accordance with Section 6(d)(ii)) on which that amount is payable, the
Default Rate;

(c) in respect of all other obligations payable or deliverable (or which would have been but for
Section 2(a)(iii)) by a Non-defaulting Party, the Non-default Rate; and

(d) in all other cases, the Termination Rate.

“consent” includes a consent, approval, action, authorisation, exemption, notice, filing,
registration or exchange control consent.

“Credit Event Upon Merger” has the meaning specified in Section 5(b).

“Credit Support Document” means any agreement or instrument that is specified as such in this
Agreement.

“Credit Support Provider” has the meaning specified in the Schedule.

“Default Rate” means a rate per annum equal to the cost (without proof or evidence of any actual
cost) to the relevant payee (as certified by it) if it were to fund or of funding the relevant
amount plus 1% per annum.

“Defaulting Party” has the meaning specified in Section 6(a).

“Early Termination Date” means the date determined in accordance with Section 6(a) or 6(b)(iii).

“Event of Default” has the meaning specified in Section 5(a) and, if applicable, in the Schedule.

“Illegality” has the meaning specified in Section 5(b).

“law” includes any treaty, law, rule or regulation and “lawful” and “unlawful” will be construed
accordingly.

11

Second
Printing

 

“Local Business Day” means, subject to the Schedule, a day on which commercial banks are open for
business (including dealings in foreign exchange and foreign currency deposits) (a) in relation to
any obligation under Section 2(a)(i), in the place(s) specified in the relevant Confirmation or, if
not so specified, as otherwise agreed by the parties in writing or determined pursuant to
provisions contained, or incorporated by reference, in this Agreement, (b) in relation to any other
payment, in the place where the relevant account is located, (c) in relation to any notice or other
communication, including notice contemplated under Section 5(a)(i), in the city specified in the
address for notice provided by the recipient and, in the case of a notice contemplated by Section
2(b), in the place where the relevant new account is to be located and (d) in relation to Section
5(a)(v)(2), in the relevant locations for performance with respect to such Specified Transaction.

“Loss” means, with respect to this Agreement or one or more Terminated Transactions, as the case
may be, and a party, an amount that party reasonably determines in good faith to be its total
losses and costs (or gain, in which case expressed as a negative number) in connection with this
Agreement or that Terminated Transaction or group of Terminated Transactions, as the case may be,
including any loss of bargain, cost of funding or, at the election of such party but without
duplication, loss or cost incurred as a result of its terminating, liquidating, obtaining or
reestablishing any hedge or related trading position (or any gain resulting from any of them).
Loss includes losses and costs (or gains) in respect of any payment or delivery required to have
been made (assuming satisfaction of each applicable condition precedent) on or before the relevant
Early Termination Date and not made, except, so as to avoid duplication, if Section 6(e)(i)(1) or
(3) or 6(e)(ii)(2)(A) applies. Loss does not include a party’s legal fees and out-of-pocket
expenses referred to under Section 9. A party will determine its Loss as of the relevant Early
Termination Date, or, if that is not reasonably practicable, as of the earliest date thereafter as
is reasonably practicable. A party may (but need not) determine its Loss by reference to
quotations of relevant rates or prices from one or more leading dealers in the relevant markets.

“Market Quotation” means, with respect to one or more Terminated Transactions and a party making
the determination, an amount determined on the basis of quotations from Reference Market-makers.
Each quotation will be for an amount, if any, that would be paid to such party (expressed as a
negative number) or by such party (expressed as a positive number) in consideration of an agreement
between such party (taking into account any existing Credit Support Document with respect to the
obligations of such party) and the quoting Reference Market-maker to enter into a transaction (the
“Replacement Transaction”) that would have the effect of preserving for such party the economic
equivalent of any payment or delivery (whether the underlying obligation was absolute or contingent
and assuming the satisfaction of each applicable condition precedent) by the parties under Section
2(a)(i) in respect of such Terminated Transaction or group of Terminated Transactions that would,
but for the occurrence of the relevant Early Termination Date, have been required after that date.
For this purpose, Unpaid Amounts in respect of the Terminated Transaction or group of Terminated
Transactions are to be excluded but, without limitation, any payment or delivery that would, but
for the relevant Early Termination Date, have been required (assuming satisfaction of each
applicable condition precedent) after that Early Termination Date is to be included. The
Replacement Transaction would be subject to such documentation as such party and the Reference
Market-maker may, in good faith, agree. The party making the determination (or its agent) will
request each Reference Market-maker to provide its quotation to the extent reasonably practicable
as of the same day and time (without regard to different time zones) on or as soon as reasonably
practicable after the relevant Early Termination Date. The day and time as of which those
quotations are to be obtained will be selected in good faith by the party obliged to make a
determination under Section 6(e), and, if each party is so obliged, after consultation with the
other. If more than three quotations are provided, the Market Quotation will be the arithmetic
mean of the quotations, without regard to the quotations having the highest and lowest values. If
exactly three such quotations are provided, the Market Quotation will be the quotation remaining
after disregarding the highest and lowest quotations. For this purpose, if more than one quotation
has the same highest value or lowest value, then one of such quotations shall be disregarded. If
fewer than three quotations are provided, it will be deemed that the Market Quotation in respect of
such Terminated Transaction or group of Terminated Transactions cannot be determined.

“Non-default Rate” means a rate per annum equal to the cost (without proof or evidence of any
actual cost) to the Non-defaulting Party (as certified by it) if it were to fund the relevant
amount.

“Non-defaulting Party” has the meaning specified in Section 6(a).

12

Second
Printing

 

“Potential Event of Default” means any event which, with the giving of notice or the lapse of time
or both, would constitute an Event of Default.

“Reference Market-makers” means four leading dealers in the relevant market selected by the party
determining a Market Quotation in good faith (a) from among dealers of the highest credit standing
which satisfy all the criteria that such party applies generally at the time in deciding whether to
offer or to make an extension of credit and (b) to the extent practicable, from among such dealers
having an office in the same city.

“Scheduled Payment Date” means a date on which a payment or delivery is to be made under Section
2(a)(i) with respect to a Transaction.

“Set-off” means set-off, offset, combination of accounts, right of retention or withholding or
similar right or requirement to which the payer of an amount under Section 6 is entitled or subject
(whether arising under this Agreement, another contract, applicable law or otherwise) that is
exercised by, or imposed on, such payer.

“Settlement Amount” means, with respect to a party and any Early Termination Date, the sum of:—

(a) the Market Quotations (whether positive or negative) for each Terminated Transaction or group
of Terminated Transactions for which a Market Quotation is determined; and

(b) such party’s Loss (whether positive or negative and without reference to any Unpaid Amounts)
for each Terminated Transaction or group of Terminated Transactions for which a Market Quotation
cannot be determined or would not (in the reasonable belief of the party making the determination)
produce a commercially reasonable result.

“Specified Entity” has the meaning specified in the Schedule.

“Specified Indebtedness” means, subject to the Schedule, any obligation (whether present or future,
contingent or otherwise, as principal or surety or otherwise) in respect of borrowed money.

“Specified Transaction” means, subject to the Schedule, (a) any transaction (including an agreement
with respect thereto) now existing or hereafter entered into between one party to this Agreement
(or any Credit Support Provider of such party or any applicable Specified Entity of such party) and
the other party to this Agreement (or any Credit Support Provider of such other party or any
applicable Specified Entity of such other party) which is a rate swap transaction, basis swap,
forward rate transaction, commodity swap, commodity option, equity or equity index swap, equity or
equity index option, bond option, interest rate option, foreign exchange transaction, cap
transaction, floor transaction, collar transaction, currency swap transaction, cross-currency rate
swap transaction, currency option or any other similar transaction (including any option with
respect to any of these transactions), (b) any combination of these transactions and (c) any other
transaction identified as a Specified Transaction in this Agreement or the relevant confirmation.

13

Second
Printing

 

“Terminated Transactions” means with respect to any Early Termination Date (a) if resulting from a
Termination Event, all Affected Transactions and (b) if resulting from an Event of Default, all
Transactions (in either case) in effect immediately before the effectiveness of the notice
designating that Early Termination Date (or, if “Automatic Early Termination” applies, immediately
before that Early Termination Date).

“Termination Event” means Illegality or, if specified to be applicable, a Credit Event Upon Merger
or an Additional Termination Event.

“Termination Rate” means a rate per annum equal to the arithmetic mean of the cost (without proof
or evidence of any actual cost) to each party (as certified by such party) if it were to fund or of
funding such amounts.

“Unpaid Amounts” owing to any party means, with respect to an Early Termination Date, the aggregate
of (a) in respect of all Terminated Transactions, the amounts that became payable (or that would
have become payable but for Section 2(a)(iii)) to such party under Section 2(a)(i) on or prior to
such Early Termination Date and which remain unpaid as at such Early Termination Date and (b) in
respect of each Terminated Transaction, for each obligation under Section 2(a)(i) which was (or
would have been but for Section 2(a)(iii)) required to be settled by delivery to such party on or
prior to such Early Termination Date and which has not been so settled as at such Early Termination
Date, an amount equal to the fair market value of that which was (or would have been) required to
be delivered as of the originally scheduled date for delivery, in each case together with (to the
extent permitted under applicable law) interest, in the currency of such amounts, from (and
including) the date such amounts or obligations were or would have been required to have been paid
or performed to (but excluding) such Early Termination Date, at the Applicable Rate. Such amounts
of interest will be calculated on the basis of daily compounding and the actual number of days
elapsed. The fair market value of any obligation referred to in clause (b) above shall be
reasonably determined by the party obliged to make the determination under Section 6(e) or, if each
party is so obliged, it shall be the average of the fair market values reasonably determined by
both parties.

IN WITNESS WHEREOF the parties have executed this document on the respective dates specified below
with effect from the date specified on the first page of this document.

	 	 	 	 	 	 	 	 	 	 	 
	First National Bank of Omaha
	 	 	 	 	 	Cardinal Ethanol, LLC	 	 
	 

	 	(Name of Party)
	 	 	 	 	 	(Name of Party)	 	 
	 
	 	 	 	 	 	 	 	 	 	 
	By:

	 	/s/ Fallon Savage
	 	 	 	By:
	 	/s/ Troy Prescott	 	 
	 

	 	 
	 	 	 	 	 	 	 	 
	 

	 	Name: Fallon Savage
	 	 	 	 	 	Name: Troy Prescott	 	 
	 

	 	Title: Commercial Loan Officer
	 	 	 	 	 	Title: President	 	 
	 

	 	Date: 12/19/06
	 	 	 	 	 	Date: 12/19/06	 	 

14

ISDA
® 1992

Second
Printing

 

SCHEDULE
TO THE MASTER AGREEMENT

dated as of 12/19/2006

between First National Bank of Omaha and Cardinal Ethanol, LLC

	 	 	 
	(“Party A”)
	 	(“Party B”)

Part 1. Termination Provisions.

	(a)	 	“Specified Entity” means in relation to Party A for the purpose of:

	 	 	 	 	 
	 

	 	Section 5(a)(v),
	 	None
	 

	 	Section 5(a)(vi),
	 	None
	 

	 	Section 5(a)(vii),
	 	None
	 

	 	Section 5(b)(ii),
	 	None
	 	 	and in relation to Party B for the purpose of:
	 

	 	Section 5(a)(v),
	 	Any current or future Affiliate of Party B
	 

	 	Section 5(a)(vi),
	 	Any current or future Affiliate of Party B
	 

	 	Section 5(a)(vii),
	 	Any current or future Affiliate of Party B
	 

	 	Section 5(b)(ii),
	 	Any current or future Affiliate of Party B

	(b)	 	“Specified Transaction” will have the meaning specified in Section 12 of this Agreement.
	 
	(c)	 	The “Cross Default” provisions of Section 5(a)(vi) will apply to Party B.
	 
	(d)	 	“Specified Indebtedness” will have the meaning specified in Section 12 of this Agreement.
	 
	(e)	 	“Threshold Amount” means $100,000.
	 
	(f)	 	The “Credit Event Upon Merger” provisions of Section 5(b)(ii) will apply to Party B.
	 
	(g)	 	The “Automatic Early Termination” provision of Section 6(a) will not apply to Party A or Party
B.
	 
	(h)	 	Payments on Early Termination. For the purpose of Section 6(e) of this Agreement:
	 
	 	 	The Second Method and Market Quotation will apply.
	 
	(i)	 	Additional Termination Event: For the purpose of Section 5(b)(iii) of this Agreement, it
shall be an “Additional Termination Event” with Party B being the Affected Party if (i) the
loan or other indebtedness in connection with which a Transaction is entered into by Party B
for the purpose or with the effect of altering the net combined payment of Party B from a
floating to fixed or a fixed to floating rate basis is repaid, whether upon acceleration of
principal, at maturity, or otherwise, or for any other reason ceases to be an obligation of
Party B, with or without the consent of Party A, or (ii) any Credit Support Document expires,
terminates, or ceases to be in full force and effect for the purpose of this Agreement unless
this Agreement is expressly amended in writing to reflect that it is no longer a Credit
Support Document hereunder, or (iii) Party A and Party B or any current or future Affiliate of
Party B fail to enter into any future anticipated loan to or other indebtedness of Party B or

 Page 1 of 4

 

	 	 	any current or future Affiliate of Party B in the amount of the Notional Amount of a Transaction
that is entered into in anticipation of such loan or other indebtedness and by the Effective
Date of such Transaction.

Part 2. Agreement to Deliver Documents.

For the purpose of Section 4(a) of this Agreement, Party B agrees to deliver the following
documents:

	(a)	 	A certificate of an authorized officer of Party B evidencing the necessary corporate
authorizations, resolutions, and approvals with respect to the execution, delivery and
performance of this Agreement, and certifying the names, true signatures, and authority of the
officer(s) signing this Agreement and executing Transactions hereunder.
	 
	(b)	 	Quarterly and annual financial statements of Party B when requested by Party A.
	 
	(c)	 	IRS Form W-9 of Party B when requested by Party A.

Part 3. Miscellaneous.

(a) Addresses for Notices: For the purpose of Section 10(a) of this Agreement

Address for notices or communications to Party A:

Address: 1620 Dodge Street – Mail Stop 1089 Omaha, NE 68197

Attention: Justin Vossen – Investment Officer

Facsimile No.: (402) 633-7499            Telephone No.: (402) 633-7489

Address for notices or communications to Party B:

	 	 	 	 	 	 	 	 	 
	 

	 	Address:	 	 	 	 	 	 
	 	 	 	 	 
	 
	 	 	 	 	 	 	 	 
	 

	 	Attention:	 	 	 	 	 	 
	 	 	 	 	 
	 
	 	 	 	 	 	 	 	 
	 

	 	Facsimile No.:
	 	 	 	Telephone No.:	 	 
	 

	 	 	 	 
	 	 	 	 

	(b)	 	Calculation Agent. The Calculation Agent is Party A.
	 
	(c)	 	Credit Support Document: In relation to Party B, means any guarantee, security agreement, or
other document in effect from time to time that by its terms guarantees or otherwise supports
the full and timely performance of Party B’s obligations under this Agreement.
	 
	(d)	 	Credit Support Provider: Any individual or entity named in a Credit Support Document who is
securing Party B’s full and timely performance of its obligations to Party A under such
documents, including without limitation guarantors.
	 
	(e)	 	Governing Law. This Agreement will be governed by and construed in accordance with the laws
of the State of New York without reference to choice of law doctrine.
	 
	(f)	 	Definitions. Section 12 is modified as follows:

(i) “Default Rate” means Party A’s “National Base Rate” plus 6% per annum

 Page 2 of 4

 

	(g)	 	Payments.

Party A will make payments to Party B by transfer to the account of Party B at First
National Bank of Omaha (Account Number:                                         ).

Party B will make payments to Party A by transfer from the account of Party B at First
National Bank of Omaha (Account Number:                                         ), and Party A is irrevocably
authorized to debit such account for each such payment (it being understood that Party B
will at all times maintain sufficient balances in such account for such purposes).

Part 4. Other Provisions.

	(a)	 	Additional Representations. Party B represents to Party A (which representation will be
deemed to be repeated by Party B on each date on which a Transaction is entered into) that it,
or any Credit Support Provider, has: (A) if a corporation, partnership, proprietorship,
limited liability company or trust, (1) total assets exceeding $10,000,000 or (2) a net worth
exceeding $1,000,000 and is entering into the Transaction in connection with the conduct of
its business or to manage the risk associated with an asset or liability owned or incurred in
the conduct of its business, or (B) if an individual, total assets exceeding (1) $10,000,000
or (2) $5,000,000 and who is entering into the Transaction to manage the risk associated with
an asset owned or liability incurred, or reasonably likely to be owned or incurred, by the
individual.
	 
	(b)	 	Event of Default. Each Party agrees to notify the other party of the occurrence of any Event
of Default or Potential Event of Default immediately upon learning of the occurrence thereof.
	 
	(c)	 	Disclaimer. In entering into this Agreement, Party B understands that there is no assurance
as to the direction in which interests rates in financial markets may move in the future and
that Party A makes no covenant, representation, or warranty in this regard or in regard to the
suitability of the terms of the Agreement or any Transaction to the particular needs and
financial situation of Party B. Party B represents, which representation shall be deemed
repeated with respect to and at the time of each Transaction, that (A) it has had the
opportunity, independently of Party A and Party A’s affiliates, officers, employees, and
agents, to consult its own financial advisors and has determined that it is in Party B’s
interest to enter into the Agreement and any Transaction and (B) it is capable of assuming and
assumes the risks of any Transaction. Party A is not acting as a fiduciary for or advisor to
Party B in respect of any Transaction.
	 
	(d)	 	Waiver of Jury Trial. Each party hereby irrevocably waives, to the fullest extent permitted
by applicable law, any and all rights it may have to trial by jury in respect of any
proceedings arising out of or relating to this Agreement or any Transaction and acknowledges
that it and the other party have been induced to enter into this Agreement by, among other
things, these mutual waivers.
	 
	(e)	 	Set-off. The right to exercise a Set-off against any amount otherwise payable in respect of
an Early Termination Date pursuant to Section 6(e) may be applied solely at the election of
the Non-Defaulting Party in the case of an Event of Default, and by the party other than the
Affected Party in the case of a Termination Event or Additional Termination Event, whether or
not such party is the payer or payee of an amount determined pursuant to Section 6. If an
obligation is unascertained, such party may in good faith estimate that obligation and
exercise a Set-off in respect of the estimate, subject to the relevant party accounting to the
other party when the obligation becomes ascertained.

 Page 3 of 4

 

	(f)	 	Jurisdiction. Section 11 (b)(i) is modified to read:

(i) submits to the jurisdiction of the jurisdiction of the courts of the State of Nebraska
and the United Stated District Court located in Omaha, Nebraska

	 	 	 	 	 	 	 	 	 	 	 
	First National Bank of Omaha
	 	 	 	Cardinal Ethanol, LLC
	 	 
	 
	 	 	 	 	 	 	 	 	 	 
	By:

	 	/s/ Fallon Savage
	 	 	 	By:
	 	/s/ Troy Prescott	 	 
	 

	 	 
	 	 	 	 	 	 	 	 
	 

	 	Name: Fallon Savage
	 	 	 	 	 	Name: Troy Prescott	 	 
	 

	 	Title: Commercial Loan Officer
	 	 	 	 	 	Title: President 	 	 

 Page 4 of 4exv10w1

 

Exhibit 10.1

FORM 6281 (6-2006)

Page 1 of 39

39

Farm Credit Services of America

CREDIT AGREEMENT

This Credit Agreement (“Agreement”) dated as of August 25, 2006 by and between Farm Credit
Services of America, FLCA and Farm Credit Services of America, PCA (“Lender”) and E Energy Adams,
LLC (“Borrower”), in consideration of credit extended by Lender under the terms and conditions set
forth below, the parties hereto agree as follows:

ARTICLE 1 — DEFINITIONS

As used in this Agreement, the following terms shall have the meanings set forth below (and such
meaning shall be equally applicable to both the singular and plural form of the terms defined, as
the context may require):

‘Advance’ shall mean funds advanced to the Borrower under the Credit Facility(ies) described in
Article 2 herein.

‘Affiliate’ shall mean any person, firm or corporation (other than a Subsidiary) which directly or
indirectly, is in control of, is controlled by, or is under common control with, any other person,
firm or corporation.

‘Business Day’ shall mean a day, other than a Saturday or Sunday, on which commercial banks are
open for business in Omaha, Nebraska.

‘Capital Expenditures’ means, for any period, without duplication, (a) the additions to property,
plant and equipment and other capital expenditures of Borrower that are (or would be) set forth on
a statement of cash flows of Borrower for such period prepared in accordance with GAAP and (b)
Capital Lease Obligations incurred by Borrower during such period.

‘Closing Date’ shall mean that date on which the Lender and Borrower have executed all Loan
Documents to which they are parties and on which all conditions in Article 3 have been met.

‘Code’ means the Internal Revenue Code of 1986, as amended and in effect from time to time.

‘Collateral’ shall mean the property described in Article 4, together with any other personal or
real property in which the Lender may be granted a lien or security interest to secure payment of
the Loan and together with the Assignment of all Contracts or Agreements required herein.

‘Construction Contract’ shall mean that principal contract between Borrower and any third parties
and any addenda thereto for construction of the Facility.

‘Control’ shall mean possession, directly or indirectly, of power to direct or cause the direction
of management or policies, whether through ownership of voting securities, by contract or
otherwise.

‘Debt’ or ‘Indebtedness’ shall mean (i) indebtedness of such Borrower for borrowed money, (ii)
indebtedness of such Borrower for the deferred purchase price of property or services (except trade
payables arising in the ordinary course of business), (iii) guarantees, endorsements (other than
for collection in the ordinary course of business) and other contingent obligations of such
Borrower to purchase, to provide funds for payment, to supply funds to invest in any person,
corporation or other entity or otherwise to assure a creditor against loss, (iv) obligations of
such Borrower under leases which shall have been or should be in accordance with GAAP, recorded as
capital leases, (v) Unfunded Benefit Liabilities of such Borrower and (vi) any liability that would
be classified as indebtedness in accordance with GAAP.

‘Default Rate’ shall mean a rate which is 4 percent per annum higher than the highest rate of
interest otherwise then accruing on all or any portion of the Loan.

‘Deposit Accounts’ means all demand, time, savings, passbook or similar depository accounts of
Borrower with financial institutions, including but not limited to Borrower’s operating, payroll
and other bank or depository accounts.

‘Disbursing Agent’ is initially Union Title Company, and in the event Union Title Company ceases to
act as Disbursing Agent, the Disbursing Agent will be a Person selected by Lender who succeeds to
such duties.

‘Dollar’ and ‘$’ shall mean dollars in lawful currency of the United States of America.

 

 

FORM 6281 (6-2006)

Page 2 of 39

39

‘Earnings Before Interest and Taxes’ shall mean the sum of net income of the Borrower on a
consolidated basis, plus interest expense and all charges against such income for such period for
federal, state, and local taxes actually paid or provided for as a dividend declared but unpaid.

‘Environmental Laws’ shall mean any and, all federal, state, and local statutes, laws, regulations,
ordinances, rules, judgments, orders, decrees, permits, concessions, grants, franchises, licenses,
agreements or other governmental restrictions relating to the environment or to emissions,
discharges, releases or threatened releases of pollutants, contaminants, chemicals or industrial,
toxic or hazardous substances or wastes into the environment, including, without limitation,
ambient air, surface water, ground water or land, or otherwise relating to the manufacture,
processing, distribution, use, treatment, storage, disposal, transport or handling of pollutants,
contaminants, chemicals, or industrial, toxic or hazardous substances or wastes.

‘ERISA’ shall mean the Employee Retirement Income Security Act of 1974, as amended from time to
time, including any rules and regulations promulgated thereunder.

‘ERISA Affiliate’ means any trade or business which, together with Borrower, is treated as a single
employer under Section 414 of the Code.

‘ERISA Event’ means (a) any reportable event, as defined in Section 4043 of ERISA or the
regulations issued thereunder with respect to a plan; (b) the existence of an “accumulated funding
deficiency”; (c) the filing of an application for a waiver of the minimum funding standard with
respect to any plan; (d) the incurrence by Borrower or any of its ERISA Affiliates of any liability
with respect to the termination of any plan; (e) the receipt by Borrower or the ERISA Affiliate of
any notice relating to an intention to terminate any plan or to appoint a trustee to administer any
plan (f) the incurrence by Borrower or any of its ERISA Affiliates of any liability with respect to
the withdrawal or partial withdrawal from any plan; or (g) the receipt by Borrower or any ERISA
Affiliate of any notice concerning the imposition of withdrawal liability.

‘Event of Default’ shall have the meaning set forth in Article 8 and the term “Potential Default”
shall mean any event or condition, which, with the lapse of time, or giving of notice, or both,
would constitute an Event of Default.

‘Excess Cash Flow’ shall mean net income for the fiscal year, plus depreciation and amortization
expenses minus permitted Capital Expenditures, distributions and withdrawals, both as defined in
Section 7.12, and regularly scheduled payments under the Loans and other term loan payments to
other long-term creditors if permitted by Lender.

‘Facility’ shall mean the ethanol facilities to be constructed or operated by Borrower on the real
estate described in Exhibit “A” attached hereto.

‘GAAP’ shall mean those generally accepted accounting principles set forth in Statements of the
Financial Accounting Standards Board and in Opinions of the Accounting Principles Board of the
American Institute of Certified Public accountants or which have other substantial authoritative
support in the United States of America and are applicable in the circumstances, as applied on a
consistent basis. “Consistent basis” shall, however, mean not only that the accounting principles
observed in the current period are comparable in all material respects to those applied in the
preceding period, but that, in the case of Financial Statements furnished to Banks, the methods of
calculation, aggregation and presentation of the balance sheet, statements of income and retained
earnings and statements of cash flows shall be substantially the same as those used for the Initial
Financial Statements.

‘Investment Accounts’ means all securities or investment accounts of Borrower with brokerage firms
and others.

‘Lien’ shall mean any mortgage, deed of trust, pledge, charge, hypothecation, assignment, deposit
arrangement, encumbrance, lien (statutory or other), preference, priority or other security
agreement or preferential arrangement of any kind or nature whatsoever, including, without
limitation, any conditional sale or other title retention agreement, any financing lease having
substantially the same economic effect as any of the foregoing and the filing of any financing
statement under the UCC (other than any such financing statement filed for informational purposes
only) or comparable law or any jurisdiction to evidence any of the foregoing.

‘Loan’ or ‘Loans’ shall mean the Loan Facility(ies) identified in Article 2 herein.

 

 

FORM 6281 (6-2006)

Page 3 of 39

39

‘Loan Documents’ shall mean this Agreement, and any other document or instrument executed in
connection with or evidencing the Loan.

Management Contracts’ means all agreements and contracts, if any, which are material to the
management of Borrower’s business in effect presently and entered into from time to time hereafter,
as the same may be amended, restated, supplemented or otherwise modified from time to time.

‘Material Adverse Effect’ shall mean any event, occurrence or circumstance that has a material
negative effect on (i) the business, operations, property, and financial condition of the Borrower,
or (ii) the validity or enforcement of any of the Loan Documents or the rights or remedies of the
Lender hereunder, or (iii) the ability of the Borrower to perform its obligations under any of the
Loan Documents.

‘Material Contracts’ means (a) the Construction Contract, other prime, subcontractor and materials
contracts, Management Contracts, Supply Contracts, Sales and Marketing Contracts, Transportation
Contracts, Utility Contracts, process and performance guarantees, and any license agreement; and
(b) such other agreements and contracts to which Borrower is or becomes a party that are material
to the operation of Borrower’s business.

‘Obligations’ shall mean any Advances and other amounts due to Lender under the Loan Documents,
including without limitation, principal, interest, fees, costs, and expenses, together with all
renewals, extensions, or refinancing and also all other indebtedness and/or liabilities of Borrower
to Lender.

‘Permitted Investments’ shall mean:

     (a) direct obligations of, or obligations the principal of and interest on which are
unconditionally guaranteed by, the United States of America (or by any agency thereof to the extent
such obligations are backed by the full faith and credit of the United States), in each case
maturing within one year from the date of acquisition thereof;

     (b) commercial paper having the highest rating, at the time of acquisition thereof, of S&P or
Moody’s and in either case maturing within six months from the date of acquisition thereof;

     (c) certificates of deposit, bankers’ acceptances and time deposits maturing within 180 days
of the date of acquisition thereof issued or guaranteed by or placed with, and money market deposit
accounts issued or offered by, any domestic office of any commercial bank organized under the laws
of the United States of America or any state thereof which has a combined capital and surplus and
undivided profits of not less than $500,000,000;

     (d) fully collateralized repurchase agreements with a term of not more than 30 days for
securities described in clause (a) above and entered into with a financial institution satisfying
the criteria described in clause (c) above;

     (e) mutual funds investing solely in any one or more of the Permitted Investments described in
clauses (a) through (d) above;

     (f) Hedging Agreements entered into in the ordinary course of business solely to hedge or
mitigate risks to which Borrower is exposed in the conduct of its business or management of its
liabilities; and the Lender Stock.

‘Permitted Liens’ shall mean: (i) liens and security interests securing indebtedness owed by the
Borrower to the Lender; (ii) liens for taxes, assessments or similar charges not yet due; (iii)
liens of material men, mechanics, warehousemen, or carriers or other like liens arising in the
ordinary course of business and securing obligations which are not yet delinquent; (iv) purchase
money liens or purchase money security interests upon or in any property acquired or held by the
Borrower in the ordinary course of business to secure indebtedness outstanding on the date hereof;
(v) liens and security interests which, as of the date hereof, have been disclosed to and approved
by the Lender in writing or as set forth in an attached Schedule hereto; and (vi) those liens and
security interests which in the aggregate constitute an immaterial and insignificant monetary
amount with respect to the net value of the Borrower’s assets.

‘Person’ shall mean any individual, corporation, partnership, joint venture, association, joint
stock company, trust, unincorporated organization or government.

 

 

FORM 6281 (6-2006)

Page 4 of 39

39

‘Request’ shall mean a communication (by telephone, letter, fax or otherwise) from a person
reasonably believed by Lender to be the Borrower or an authorized officer or manager of Borrower
making the Request upon which Lender shall be entitled to rely.

‘Sales and Marketing Contracts’ means all agreements and contracts in effect presently and entered
into from time to time hereafter which are material to the sale or disposal of products and
by-products produced by Borrower, as such agreements and contracts are amended, restated,
supplemented or otherwise modified from time to time.

‘Subordinated Debt’ shall mean such liabilities of the Borrower which have been subordinated to
those owed to the Lender in a manner acceptable to the Lender.

‘Subsidiary’ shall mean any corporation, partnership, association, joint venture, limited liability
company, or other unincorporated organization or entity with respect to which Borrower has voting
power to elect a board of directors (or other similar governing body), or has the power under
ordinary circumstances to directly or indirectly control the management thereof.

‘Substantial Completion’ shall be deemed to occur on the date on which the Construction Contract is
sufficiently complete so that Borrower can occupy and use the Facility for its intended purposes.
Substantial Completion shall be attained at the point in time when the Facility is ready to grind
corn and begin operation for its intended use as a 50 MGY fuel ethanol production plant.

‘Supply Contracts’ means all agreements and contracts related to the supply of inputs material to
the operation of Borrower’s business in effect presently and entered into from time to time
hereafter, as the same such agreements and contracts are amended, restated, supplemented or
otherwise modified from time to time.

‘Transportation Contracts’ means all agreements and contracts in effect presently and entered into
from time to time hereafter related to the provision of transportation or shipping services which
are material to the operation of Borrower’s business as the same such agreements and contracts are
amended, restated, supplemented or otherwise modified from time to time.

‘Utility Contracts’ means all contracts and agreements in effect presently and entered into from
time to time hereafter which are material to the provision to Borrower of necessary electricity,
natural gas, water, fuel oil, coal and other energy resources in connection with the operation of
Borrower’s facility, equipment and offices, as the same such agreements and contracts are amended,
restated, supplemented or otherwise modified from time to time.

ARTICLE 2 — CREDIT FACILITIES

Subject to the terms and conditions set forth in this Agreement, Lender agrees to make Advances to
Borrower on any Business Day from the date hereof to, but excluding the Final Advancement Date
identified for said Advances, so long as no Event of Default or Potential Default has occurred.
Lender agrees to advance sums to Borrower not to exceed the lesser of 65% of the Facility appraised
value, and $49,500,000.00, as represented by Credit Facility A, Credit Facility B and Credit
Facility C described below.

Section 2.1. Credit Facility A. Lender agrees to advance sums to Borrower up to the
amount of $35,000,000.00 (Maximum Principal Balance) until April 1, 2008 (Term Loan Final
Advancement Date). Each Advance made will reduce the funds available for future advances by the
amount of the Advance. Repayments of principal will not be available for subsequent Advances. The
proceeds of said Loan will be used by Borrower for financing the construction of a 50 million
gallon dry mill ethanol plant (Purpose) and Borrower agrees not to request or use such proceeds for
any other purpose.

	 	(a)	 	Interest. Borrower hereby promises to pay interest on the principal indebtedness
outstanding from time to time on each Advance from and including the date of such Advance
and otherwise in accordance with statements issued by Lender. Interest shall be payable on
the following dates, each such date an “Interest Payment Date”, provided that interest
accruing at the Default Rate, if applicable, shall be payable on demand.
	 
	 	 	 	Said interest shall be payable on the 1st day of each month, commencing the
first day of the month following the first Advance through and including the Term Loan
Final Advancement Date. Commencing on the First Principal Payment Date, as set forth in
Section 2.1(b), said interest shall be payable on the principal payment installment due
dates at the following rate per annum.

 

 

FORM 6281 (6-2006)

Page 5 of 39

39

Libor Rate Libor Rate interest shall accrue from the date of each Advance at a variable rate per
annum equivalent to the Libor Short Term Index Rate plus 3.05% (the ‘Variable Rate’). Interest
rate shall be adjusted higher or lower on September 15, 2006, and every month thereafter with any
change in the Libor Rate and this higher or lower rate will thereafter apply to the outstanding
principal indebtedness and remain in effect until a different rate of interest is established. The
amount of any subsequent payments will be increased or decreased accordingly to reflect the
different rate of interest without in any manner changing the due date of the payments. There is
no limitation on the frequency or the amount of the change in the interest rate.

The Variable Rate shall be adjusted to the Libor Short Term Index Rate Index listed below for any
year after the first year of operations in which, at the end of the preceding year, Borrower’s
Owner Equity (defined as net worth to total tangible assets) is equal to or greater than the
percentages given, provided the Borrower is not otherwise in default.

Owner Equity >/=60%      Libor + 280 basis points

The Libor Short Term Index Rate is the three-month London InterBank Offered Rates in the London
market based on the Libor rate published on the last business day of the month as published in the
Wall Street Journal, rounded to the nearest 0.05%.

     (b) Principal. Borrower hereby promises to pay principal plus all accrued interest as
follows: in 29 equal installments of $1,237,500.00 plus accrued interest commencing on the first of
the month which is six months following Substantial Completion, but no later than April 1, 2008,
(the “First Principal Payment Date”) and continuing on the 1st of each quarter
thereafter until the entire unpaid principal, plus all accrued interest and any unpaid fees, costs
or expenses is paid in full, and no later than October 1, 2015 (Maturity Date). The actual payment
amount of all other payments may vary according to the interest rate then in effect and the
outstanding principal balance.

Section 2.2 Credit Facility B. Lender agrees to advance sums to Borrower up to the amount
of $14,500,000.00 (Maximum Principal Balance) becoming available September 1, 2007 until the
expiration of 30 months after Credit Facility A has been repaid, but not later than April 1, 2018
(The Revolving Loan Final Advancement Date). Each Advance made will reduce the funds available for
future advances by the amount of the Advance. Repayments of principal will be available for
subsequent Advances, however until the Revolving Loan Final Advancement Date, the Maximum Principal
Balance available for subsequent Advances shall be reduced by $1,450,000.00 on each installment due
date. The proceeds of said Loan will be used by Borrower for financing construction of a 50
million gallon dry mill ethanol plant and to provide working capital (Purpose) and Borrower agrees
not to request or use such proceeds for any other purpose.

     (a) Interest. Borrower hereby promises to pay interest on the principal indebtedness
outstanding from time to time on each Advance from and including the date of such Advance and
otherwise in accordance with statements issued by Lender. Interest shall be payable on the
following dates, each such date an “Interest Payment Date”, provided that interest accruing at the
Default Rate, if applicable, shall be payable on demand.

Said interest shall be payable on the 1st day of each month, commencing the first day of
the month following the first Advance. Commencing on the First Principal Revolving Loan Payment
Date, as set forth in Section 2.2(b), said interest shall be payable on the principal payment
installment due dates at the following rate per annum.

Libor Rate Libor Rate interest shall accrue from the date of each Advance at a variable rate per
annum equivalent to the Libor Short Term Index Rate plus 3.05% (the ‘Variable Rate’). Interest
rate shall be adjusted higher or lower on September 15, 2006, and every month thereafter with any
change in the Libor Rate and this higher or lower rate will thereafter apply to the outstanding
principal indebtedness and remain in effect until a different rate of interest is established. The
amount of any subsequent payments will be increased or decreased accordingly to reflect the
different rate of interest without in any manner changing the due date of the payments. There is
no limitation on the frequency or the amount of the change in the interest rate.

The Variable Rate shall be adjusted to the Libor Short Term Index Rate Index listed below for any
year after the first year of operations in which, at the end of the preceding year, Borrower’s
Owner Equity (defined as net worth to total tangible assets) is equal to or greater than the
percentages given, provided the Borrower is not otherwise in default.

Owner Equity >/=60%      Libor + 280 basis points

 

 

FORM 6281 (6-2006)

Page 6 of 39

39

The Libor Short Term Index Rate is the three-month London InterBank Offered Rates in the London
market based on the Libor rate published on the last business day of the month as published in the
Wall Street Journal, rounded to the nearest 0.05%.

     (b) Principal. Borrower hereby promises to pay principal plus all accrued interest
as follows: in 10 equal installments of $1,450,000.00 plus accrued interest, the first of said
installments due January 1, 2016 or the first day of the first month which is three months
following full repayment of Credit Facility A, whichever occurs first (the “First Principal
Revolving Loan Payment Date”), and continuing on the 1st of each calendar quarter
thereafter, up to and including April 1, 2018 when the entire unpaid principal, plus all accrued
interest and any unpaid fees, costs and expenses shall be due and payable in full. The actual
payment amount of all payments may vary according to the interest rate then in effect and the
outstanding principal balance.

Section 2.3 Credit Facility C. Lender agrees to advance sums to Borrower up to the amount
of $3,000,000.00 (Maximum Principal Balance) becoming available November 1, 2007 until November 1,
2008 (Final Advancement Date). Each Advance made will reduce the funds available for future
advances by the amount of the Advance. Repayments of principal will be available for subsequent
Advances. The proceeds of said Loan will be used by Borrower for the financing of eligible grain
inventory, receivables and margin account equity (Purpose) and Borrower agrees not to request or
use such proceeds for any other purpose.

     (a) Interest. Borrower hereby promises to pay interest on the principal indebtedness
outstanding from time to time on each Advance from and including the date of such Advance and
otherwise in accordance with statements issued by Lender. Interest shall be payable on the
following dates, each such date an “Interest Payment Date”, provided that interest accruing at the
Default Rate, if applicable, shall be payable on demand.

Said interest shall be payable on the 1st day of each month at the following rate per
annum.

Libor Rate Libor Rate interest shall accrue from the date of each Advance at a variable rate per
annum equivalent to the Libor Short Term Index Rate plus 3.05% (the ‘Variable Rate’). Interest
rate shall be adjusted higher or lower on September 15, 2006, and every month thereafter with any
change in the Libor Rate and this higher or lower rate will thereafter apply to the outstanding
principal indebtedness and remain in effect until a different rate of interest is established. The
amount of any subsequent payments will be increased or decreased accordingly to reflect the
different rate of interest without in any manner changing the due date of the payments. There is
no limitation on the frequency or the amount of the change in the interest rate.

The Libor Short Term Index Rate is the three-month London InterBank Offered Rates in the London
market based on the Libor rate published on the last business day of the month as published in the
Wall Street Journal, rounded to the nearest 0.05%.

     (b) Principal. Borrower hereby promises to pay principal, plus all accrued
interest and any unpaid fees, costs or expenses in full on November 1, 2008.

Section 2.4 Computation. Interest shall be computed on the basis of a 360 day year, but
charged on the actual number of days elapsed. If interest is not paid as and when it is due, it
may be added to the principal, become and be treated as a part thereof, and shall thereafter bear
like interest.

Section 2.5 Fees. Borrower agrees to pay the following fees, in addition to those costs
and expenses referenced in Section 9.5 of this Agreement.

Section 2.5.1 Origination Fee. Borrower agrees to pay Lender for structuring the
Loan the fee set forth in the separate fee letter agreement executed by the Borrower and the
Lender dated [?November 14, 2005?]. Borrower shall receive credit towards any fees for any
amounts previously paid to Lender.

Section 2.5.2 Administrative Fee. Borrower agrees to pay Lender an annual,
non-refundable, non-prorated fee in an amount of $25,000.00, in arrears annually with the
first such payment due at the end of the second quarter following Substantial Completion and
thereafter on each annual anniversary of the payment of the administrative fee.

 

 

FORM 6281 (6-2006)

Page 7 of 39

39

Section 2.5.3 Non-Use Fee. Borrower agrees to pay Lender an additional fee in the
event that the average outstanding principal balance on Credit Facility B or Credit Facility
C is less than the Maximum Principal Balance of said facilities. This fee will be equal to .5% per annum of the difference between the Maximum Principal Balance and the actual usage.
The actual usage will be calculated as the average outstanding principal balance for each 3
month period beginning September 1, 2007 for Credit Facility B and November 1, 2007 for
Credit Facility C (Beginning Dates). The fee shall be due and payable on the first calendar quarter
following the Beginning Date and on the first of each quarter thereafter.

Section 2.6 Repayment. Borrower agrees to pay Lender, at the location identified by
Lender, the entire unpaid principal balance, plus interest, fees and other Lender’s costs and
reasonable expenses in U.S. dollars in accordance with this Agreement and the following provisions.
If any payment of principal or interest falls due on a day that is not a Business Day, then such
due date shall be extended to the next following Business Day. On loans not in default, other than
loans with revolving credit, all payments received will first be applied to protective advances and
fees, then to accrued interest, and finally to principal. On Loans with revolving credit, unless
the payment is designated by Borrower as an interest payment, payments shall first be applied to
protective advances and fees, then to reduce principal and finally to accrued interest. Upon the
occurrence and continuance of an Event of Default, payments shall first be applied to default
interest, then to protective advances and fees, then to accrued interest, and finally to principal.

Funds received by Lender will be applied to reduce principal the day received, if before 5:00 p.m.,
Central Standard Time, unless received on a holiday or weekend, in which case said funds will be
credited the next Business Day. Wire transfers will be given credit the day received only if
received before 3:00 p.m., Central Standard Time.

Funds received by Lender on a revolving credit facility shall be immediately available for
re-advance under the provisions of this Agreement if made by wire transfer, cash or other method of
ensuring funds immediately available to Lender. Payment made in funds not immediately available to
Lender, shall not be available to Borrower for re-advance for two business days thereafter or until
Lender has confirmed the availability of funds whichever is the last to occur.

Section 2.6.1 Notes Evidencing Advances. The Advances of Lender shall be evidenced
by promissory notes of Borrower substantially in the form set forth in Exhibit B, payable to
the order of Lender, due on the Term Loan Final Advancement Date for Credit Facility A, and
due on the Revolving Loan Final Advancement Date for Credit Facility B and Credit Facility C
each, in the principal amount of the Loans. Lender shall record in its records the date and
amount of each Advance made by Lender, each repayment of principal thereon, and, if
applicable, the dates on which the interest for each such Advance is payable. The aggregate
unpaid principal amount so recorded shall be rebuttable presumptive evidence of the principal
amount owing and unpaid on such Note. The failure to so record any such amount shall not,
however, limit or otherwise affect the obligations of Borrower hereunder or under any Note to
repay the principal amount of the Advances, together with all interest accruing thereon.

Section 2.7 Prepayment. This provision applies to all prepayments of principal, whether
mandatory or voluntary (except for excess cash flow payments), which prepay the Loan in full or
which exceed any scheduled principal payments.

Section 2.7.1 Voluntary Prepayments. Subject to the payment of any applicable
prepayment fees or funding losses as provided herein, Borrower may prepay the Loan in full
before its maturity or make additional principal payments on a term Loan in any amount on any
Business Day, specifying the Loan upon which any prepayment is made. Such additional
principal payment shall not, however, defer, postpone or alter the amount or due date of any
scheduled payments required under this Agreement.

Section 2.7.2 Mandatory Prepayments. If, at any time, the outstanding unpaid
principal amount on any Loan shall exceed the Maximum Principal Balance on said Loan,
Borrower shall immediately repay Advances in an amount sufficient to reduce the outstanding
unpaid principal to the Maximum Principal Balance.

 

 

FORM 6281 (6-2006)

Page 8 of 39

39

Section 2.7.3 Excess Cash Flow. In addition to the scheduled principal payments
required herein, Borrower agrees to make special principal payments equal to 65% of available
Excess Cash Flow to the extent that such payment(s) do not cause default of any of the
covenants in this Agreement. Said mandatory prepayments shall be limited to a maximum of
$2,000,000.00 per fiscal year and the aggregate total of all such payments shall not exceed
$8,000,000.00. Such payments shall be applied to scheduled principal installments of Credit
Facility A in inverse order of maturity. Any mandatory payments from Excess Cash Flow shall
be made within 120 days of the end of each fiscal year based on the Borrower’s audited
financial statements for the year just ended.

Section 2.7.4 Prepayment fees. Borrower will pay to Lender a prepayment premium in
connection with any prepayment of the Loans as a result of a refinance or payoff through
sources other than from Borrower’s operations as follows (prepayment penalties shall not
apply to any Excess Cash Flow payment made pursuant to Section 2.7.3 of this Agreement):

	 	(1)	 	3.0% of the outstanding indebtedness during the first year following the First Principal
Term Loan Payment Date and the First Principal Revolving Note Payment Date; and
	 
	 	(2)	 	2.0% of the outstanding indebtedness during the second year following the First Principal
Term Loan Payment Date and the First Principal Revolving Note Payment Date; and
	 
	 	(3)	 	1.0% of the outstanding indebtedness during the third year following the First Principal
Term Loan Payment Date and the First Principal Revolving Note Payment Date; and
	 
	 	(4)	 	0.0% thereafter.

ARTICLE 3 — CONDITIONS PRECEDENT

Section 3.1 Lender Stock. Borrower agrees to own or purchase if necessary, such stock in
Farm Credit Services of America, ACA, as is from time to time required by Lender’s policies and
bylaws. Capitalization requirements are met by stock owned by E Energy Adams, LLC. That Jack
Alderman is the authorized voter on behalf of the owner(s) of voting stock.

Section 3.2 Conditions Precedent to Closing. The obligations of Lender to close the Loans
shall be subject to the conditions precedent that Lender shall have received on or before the
Closing Date all of the following in form and substance satisfactory to Lender.

Section 3.2.1 Organizational Documents. Copies of the organizational documents of
Borrower and any Subsidiary, including certificates of good standing in their State of
organization, and copies of all resolutions, incumbency certificates or other authorizations
of Borrower and any Subsidiary, certified by the appropriate officers of such entity as being
in full force and effect authorizing, as applicable, the Loans as herein provided, and for
the execution, delivery and performance of this Agreement and the other Loan Documents or any
instruments or agreements required hereunder to which such entity is a party.

Section 3.2.2 Evidence of Insurance. Insurance certificates and such other
evidence, in form or substance satisfactory to Lender, of all insurance required to be
maintained under this Agreement and the Loan Documents.

Section 3.2.3 Loan Documents. All duly executed originals of the Loan Documents.

Section 3.2.4 Payment of Fees and Expenses. Evidence that Borrower has paid all
fees and expenses then due and payable under this Agreement.

Section 3.2.5 Title and Lien Verification. In connection with all real property
included in the Collateral, Lender shall have received either a preliminary title opinion
from an attorney acceptable to Lender or a title insurance commitment in an amount and from a
title insurance company in form, scope and substance satisfactory to Lender to assure Lender
of its lien priority as required by this Agreement and with no exceptions contained therein
except as are approved in writing by attorneys for Lender. Further, that evidence
satisfactory to Lender and the title company be obtained by Borrower establishing that all
labor and material bills have been paid and that there is no possibility of a lien for such
items which might be prior to Lender’s lien on the Collateral. In connection with all
personal property included in the Collateral, Lender shall have received searches of
appropriate filing offices showing no liens filed against the

 

 

FORM 6281 (6-2006)

Page 9 of 39

39

Collateral, except those to be
released prior to disbursement or otherwise acceptable to Lender to assure Lender of its lien
priority as required by this Agreement.

Section 3.2.6 No Material Change. No change shall have occurred in the condition,
financial or otherwise, or operation of Borrower since the Loan was approved based on
information known to Lender at time of Loan approval, which could reasonably be expected to
result in a Material Adverse Effect.

Section 3.2.7 Further Assurances. Borrower shall have provided and/or executed and
delivered to Lender such further assignments, documents or financing statements, in form and
substance satisfactory to the Lender, that Borrower is to execute and/or deliver pursuant to
the terms of the Loan Documents, this Agreement, or as Lender may otherwise reasonably
require.

Section 3.2.8 Opinion of Counsel. Borrower shall have provided a favorable opinion
of its counsel addressed to the Lender covering such matters as the Lender may reasonably
require, including, without limitation, due organization, authorization and execution of all
of the Loan Documents, enforceability, and other opinions as Lender may reasonably request.

Section 3.2.9 Secretary Certificate. A certificate of the Secretary or an Assistant
Secretary of E Energy Adams, LLC, dated as of the Closing Date, certifying: (i) true and
complete copies of the articles of organization and operating agreement (or equivalent
documents);(ii) the names and true signatures of the officers and/or directors authorized to
sign this Agreement and the other documents to be delivered hereunder; (iii) true and
complete copies of the resolutions of the board of directors of the Borrower or other
documentation providing authority for the transactions and documents contemplated hereunder;
(iv) that there is no proceeding for the dissolution or liquidation of the Borrower or
threatening its existence; and (v) that the schedules attached to the Loan Documents are true
and complete as of the Closing Date.

Section 3.2.10 Risk Management. Within 180 days of the date of this Agreement,
Borrower shall have provided Lender with their risk management policies regarding the
procurement of feedstock and marketing of ethanol and ethanol coproducts, acceptable to
Lender.

Section 3.2.11 Invested Equity. Borrower shall have provided Lender with evidence
of funding from invested equity capital, non-repayable grants and tax increment financing of
at least $53,600,000.00.

Section 3.2.12 Disbursing Agreement. A Disbursing Agreement, in a form acceptable
to Lender, shall have been executed and delivered to Lender with respect to the process by
which Advances are made of proceeds of the Loans.

Section 3.2.13 Appraisal. Lender shall have received an as-built appraisal in form
and amount satisfactory to Lender for the Facility.

Section 3.2.14 Boundary Survey. Lender shall have received in a form satisfactory
to Lender, a boundary survey of the real estate certified to Lender and the Title Company
issuing the title insurance, dated a date reasonably satisfactory to each of Lender and the
Title Company by an independent professional licensed land surveyor, which boundary survey is
sufficient to delete any standard printed survey exception contained in the title insurance
policy.

Section 3.2.15 Flood Hazard Determination. Lender shall have received a Federal
Emergency Management Agency Standard Flood Hazard Determination Certificate certifying, among
other things, whether any of the real estate Collateral is located within a flood hazard area
and, if so located, Borrower shall have provided Lender with evidence of insurance
satisfactory to Lender.

Section 3.2.16 Phase I Environmental Site Assessment. Lender shall have received a
Phase I Environmental Site Assessment Report on all of the real estate, along with such
further environmental review and audit reports as Lender requests (which may include Phase II
reports), and letters by the firm preparing such environmental reports authorizing Lender to
rely on such reports.

Section 3.2.17 Construction Documents. Lender shall have received an executed copy
of the Construction Contract and each agreement with a subcontractor (to the extent
separately requested by Lender), together with

 

 

FORM 6281 (6-2006)

Page 10 of 39

39

(A) a copy of the site plan, (B) a schedule
listing all subcontracts relating to the project, and such other contracts, subcontracts and
schedules as Lender may request, (C) a work progress schedule showing estimated completion
time for each phase of the project construction, (D) a sworn construction cost statement,
duly executed by Borrower, including a reconciliation of actual costs incurred to-date
against budgeted amounts, (E) a copy of each permit and each other building permit, license
and other agreement that Borrower is required by law to obtain in connection with the
project, together with a schedule of all other necessary licenses and permits which must be
obtained in order to occupy and operate a dry mill ethanol production facility (at maximum
capacity in accordance with the construction plans) on the real estate where the Facility
will be built, and (F) a soil report related to the real estate where the Facility will be
built, certified by a registered engineer acceptable to Lender, including structural design
recommendations in form and substance satisfactory to Lender.

Section 3.2.18 Consents and Approvals. Certified copies of all material consents,
approvals, authorizations, registrations, filings and orders required or advisable to be made
or obtained under any requirement of law or by any material contractual obligation of
Borrower, in connection with the project or operation of Borrower’s business, including the
production of ethanol and by-products thereof, and such consents, approvals, authorizations,
registrations, filings and orders must be in full force and effect and all applicable waiting
periods must have expired.

Section 3.2.19 Financial Statements. Lender shall have received copies of
Borrower’s internally prepared financial statements as of the last day of the immediately
preceding calendar quarter, and any and all prior year audited financial statements.

Section 3.2.20 Representations and Warranties. The representations and
warranties contained in this Agreement and the Loan Documents are true as of the Closing
Date.

Section 3.2.21 Material Contracts. Collateral Assignments of all Material Contracts
in existence as of the Closing Date, together with copies of such Material Contracts.

Section 3.2.22 Borrowing Base Certificate. A Borrowing Base Certificate, dated as
of the Closing Date and substantially in the form of Exhibit D hereto, dated as of the
Closing Date.

Section 3.3 Conditions Precedent to Initial Advance. The obligation of Lender to make an
initial Advance shall be subject to the conditions precedent that Lender shall have received on or
before the initial Advance all of the following in form and substance satisfactory to Lender.

Section 3.3.1 No Default. As of the Advance date, no Event of Default or Potential
Default shall have occurred and be continuing and disbursing the amount of the Advance
requested shall not result in an Event of Default or Potential Default.

Section 3.3.2 Representations and Warranties. The following statements shall be
true and the giving of a Request for an Advance by any Borrower shall be deemed to be a
representation and warranty by the Borrower that the following statements are true both on
the date of such Request and on the date of such Advance: (i) the representations and
warranties contained in Article 5 hereof and in the other documents to be delivered hereunder
are true and complete on and as of the date of such Advance as though made on and as of such
date; (ii) no event has occurred and is continuing, or would result from such Advance, which
constitutes an Event of Default or Potential Default; (iii) no Material Adverse Effect has
occurred and is continuing; (iv) the Total Lender Indebtedness does not exceed the Maximum
Principal Balance; and (v) no order, judgment or decree of any court, arbitrator or
Governmental Authority that does, or seeks to, enjoin or restrain any Lender from making any
Advance is pending or threatened.

Section 3.3.3 No Intervening Liens. Lender’s liens, security interests and
assignments have been perfected, are first priority liens, security interests and
assignments, and there are no intervening or conflicting liens (including lis pendens) on or
claims to Collateral.

Section 3.3.4 No Notice. No notice has been received from Borrower requesting
Advances under the Loan be restricted.

 

 

FORM 6281 (6-2006)

Page 11 of 39

39

Section 3.3.5 All Other Requirements Met. All other requirements precedent to
disbursal of loan funds as required by this Agreement have been met.

Section 3.3.6 Consents, Licenses and Approvals. Evidence satisfactory to Lender
that all consents, licenses and approvals of governmental authorities and third parties have
been obtained which are necessary for, or required as a condition of the validity and
enforceability of the Loan Documents.

Section 3.3.7 Engineer’s Opinion. Lender shall have received an opinion from its
engineer that all necessary permits for construction and operation have been obtained and
that there is adequate water and sanitary waste, gas and electric service available based on
needs assessment determined by Facility designers.

Section 3.3.8 Expenditure of Equity and Other Funds. Borrower has provided
documents evidencing Borrower’s expenditure of a minimum of $53,600,000.00 equity, grants,
seed capital with respect to the cost of land acquisition, construction costs, organization
costs, financing costs, and pre-production period costs.

Section 3.3.9 Confirmation of Project Costs. Borrower has provided documents and
evidence satisfactory to Lender that equity funds, seed capital, grant proceeds, tax
increment financing and the Loans are sufficient to complete construction and commence
operations in accordance with Borrower’s sworn construction cost statement and projections
for operations.

Section 3.3.10 Title Insurance. The title insurance company is willing to issue an
endorsement to the title insurance policy providing title insurance coverage for all prior
and current advances without any exceptions for liens or claims of any other Person.

Section 3.4 Conditions Precedent to Subsequent Advances. The obligation of Lender to fund
subsequent Advances is subject to Lender’s satisfaction of each of the following as well as those
in Section 3.3 and each request by Borrower for an Advance shall constitute a representation by
Borrower that all conditions precedent in this Article have been satisfied and the amount of the
Advance does not exceed the limits set forth in Article 2 hereof, or violate or exceed any other
provision of this Agreement:.

Section 3.4.1 No Default. As of the Advance date, no Event of Default or Potential
Default shall have occurred and be continuing and disbursing the amount of the Advance
requested shall not result in an Event of Default or Potential Default.

Section 3.4.2 Representations and Warranties. The following statements shall be
true, and the giving of a Request for an Advance by any Borrower shall be deemed to be a
representation and warranty by the Borrower that the following statements are true both on
the date of such Request and on the date of such Advance: (i) the representations and
warranties contained in Article 5 hereof and in the other documents to be delivered hereunder
are true and complete on and as of the date of such Advance as though made on and as of such
date; (ii) no event has occurred and is continuing, or would result from such Advance, which
constitutes an Event of Default or Potential Default; (iii) no Material Adverse Effect has
occurred and is continuing; (iv) the total Lender Indebtedness does not exceed the Maximum
Principal Balance; and (v) no order, judgment or decree of any court, arbitrator or
governmental authority that does, or seeks to, enjoin or restrain Lender from making any
Advance is pending or threatened.

Section 3.4.3 No Intervening Liens. There are no intervening or conflicting liens
(including lis pendens) on or claims to Collateral.

Section 3.4.4 No Notice. No notice has been received from Borrower requesting
Advances under the Loan be restricted.

Section 3.4.5 All Other Requirements Met. All other requirements precedent to
disbursal of loan funds as required by this Agreement have been met.

Section 3.5 Post Closing Requirements. Prior to funding any Advances on the Loan,
Borrower must deliver to Lender: assignments of all commodity hedging accounts established and all
Material Contracts Borrower shall have entered into, at the time such Advance is requested.

 

 

FORM 6281 (6-2006)

Page 12 of 39

39

Section 3.6 Post Construction Requirements, Following Substantial Completion, and prior
to the First Principal Term Loan Payment Date and the First Principal Revolving Loan Payment Date,
Borrower shall satisfy the following conditions and requirements:

Section 3.6.1
Satisfaction of Conditions Precedent. All of the conditions
precedent set forth in Section 3.2, 3.3, 3.4 and 3.5 shall have been satisfied in full.

Section 3.6.2 Appraisal. Lender shall have received, in form satisfactory to
Lender, an appraisal, or an update to the as-built appraisal obtained prior to construction
of the Facility, confirming that the appraised value of the Facility will result in the
Maximum Principal Balance not exceeding 65% of the appraised value of the Facility.

Section 3.6.3 ALTA Survey. Lender shall receive, in form satisfactory to Lender, an
ALTA as-built survey of the Facility.

Section 3.6.4 Warranties. Lender shall receive upon request, in form satisfactory
to Lender, copies of all warranties from suppliers and contractors covering materials,
equipment, appliances and the Facility.

Section 3.6.5 Completion of Construction. Lender shall receive, in form
satisfactory to Lender, a certificate from an officer of Borrower, certifying that
construction of the Facility is final and complete in accordance with the plans and
specifications provided to Lender.

Section 3.6.6 Other Documentation. Lender shall have received from Borrower such
other documents, instruments and certificates as Lender may reasonably request.

Section 3.7 Revolving Advance Requirements. As of and subsequent to completion of
construction of the Facility, requests for Advances shall be made directly to Lender and not
through the Disbursing Agent. The obligation of Lender to make Advances shall be subject to the
conditions precedent set forth in Sections 3.2, 3.3, 3.4, 3.5 and 3.6.

ARTICLE 4 — SECURITY

Section 4.1 Collateral. As security for the payment and performance of all obligations of
Borrower to Lender, including all obligations of Borrower under Article 2 hereof, any future and
additional loans or advances made to or on behalf of Borrower by Lender for any purpose, including
advances for the protection of Collateral, all attorney fees, costs, and expenses incurred by
Lender in the collection of the Loan or in the enforcement or preservation of the rights of Lender
in and to the Collateral, Borrower hereby grants to Lender a security interest in certain real or
personal property, including the following described property wherever located in which Borrower
has or claims an interest, and in all increases, additions, accessions and substitutions
(Collateral):

(a) A security interest in the following:

Accounts, General Intangibles, and Other Rights to Payment. All accounts, deposit accounts,
contract rights, general intangibles, chattel paper, investment property, documents,
instruments, money and other rights to payment now existing and hereafter acquired, from any and
all sources.

Crops. All crops now growing or hereafter planted or grown, whether harvested, unharvested or
stored; all products of crops and all seed, fertilizer, chemicals and supplies used or produced
in connection with any crop.

Feed and Grain. All feed and grain from whatever source, stored, used or to be used, whether
grown, purchased, or otherwise acquired.

Inventory. All inventory owned by or consigned to debtor of whatever nature.

Machinery and Equipment. All equipment, machinery, nontitled motor vehicles, tools, tanks, and
removable structures used or useful in farming or ranching operations, all fuel, parts,
accessories, and improvements thereto.

Fixtures. All fixtures and irrigation equipment located on the real estate upon which the
Facilities are located.

 

 

FORM 6281 (6-2006)

Page 13 of 39

39

This security interest is in addition to any security interest or other lien granted to Lender
under the terms of any Mortgage, Trust Deed or Security Agreement executed by Borrower or by any
third party or any other document or agreement. Said security interest or other lien is
continuing and shall include the proceeds and products of the Collateral, including, but limited
to, the proceeds of any insurance thereon.

(b) A lien in Borrower’s real estate, as identified in Exhibit A, pursuant to the terms of a
trust deed in form satisfactory to Lender.

(c) Assignments of Borrower’s Material Contracts.

(d) Security interests in Borrower’s Investment Accounts and Hedging Account, pursuant to
account control agreements in forms satisfactory to Lender.

Section 4.2 Collateral Matters. Until all obligations have been fully satisfied, Lender’s
security interest in the Collateral, and all proceeds and products thereof, shall continue in full
force and effect. During the term of this Agreement, Borrower shall not permit any lien, claim or
encumbrance (other than those granted to Lender and those subordinated and/or approved in writing
by Lender) to remain against any of the Collateral and Borrower shall perform any and all steps
requested by Lender to perfect, maintain and protect Lender’s security interest in the Collateral
in which a security interest is granted to Lender under this Agreement or any other agreement,
including, without limitation, executing and filing financing and continuation statements in form
and substance satisfactory to Lender. Lender may file one or more financing statements disclosing
Lender’s security agreement under this Agreement and Borrower shall pay any costs of, or incidental
to, any recording or filing of any financing statements concerning the Collateral. Borrower hereby
expressly agrees that a carbon, photographic, photostatic, or other reproduction of this Agreement
or of a financing statement is sufficient as a financing statement. And further that wherever and whenever available and allowed
by law Secured Party is authorized to file electronically all documents allowed or required by the
Uniform Commercial Code, the Federal Food Security Act, or other applicable law, including but not
limited to financing statements, effective financing statements, and continuations, amendments,
assignments, or terminations thereof, WITHOUT the physical signature of Borrower and/or this
authorization shall be deemed a digital signature, and/or this authorization shall be deemed a
limited power of attorney appointing Secured Party as Borrower’s agent and attorney-in-fact for the
express purpose of signing and executing the aforesaid documents on Borrower’s behalf. Borrower
shall pay or cause to be paid, unless contested in good faith, all taxes, assessments and
governmental charges levied, assessed or imposed upon or with respect to the Loan, the Collateral,
any part thereof, or the Lender by virtue of the Loan transaction. Unless contested in good faith,
if Borrower fails to pay such taxes, assessments and governmental charges, Lender may (but shall
not be required to) pay the same and charge the cost to the Borrower payable on demand and secured
by the Collateral.

Section 4.3 Sale of Collateral. Without Lender’s prior written consent, except for
Inventory sold in the ordinary course of business and except for Collateral with a value of less
than $75,000, Borrower will not sell, transfer, or dispose of the Collateral without applying all
proceeds of such transaction to payment of the Loan secured hereby within 10 days after the
transaction. Borrower will not take or attempt to take the Collateral from the state where kept
without the prior written consent of Lender. Upon request, Borrower will provide Lender with a
current list of all collateral and its location.

ARTICLE 5 — REPRESENTATIONS AND WARRANTIES

Borrower warrants and represents that on the Closing Date and on and after each Advance occurring
hereunder:

Section 5.1 Organization and Qualification. Borrower is duly incorporated or organized
and is validly existing as a corporation or other legal entity in good standing in the jurisdiction
of its incorporation or organization; has the power and authority to own or lease its properties
and to conduct the business in which it is now engaged or proposed to be conducted; is duly
qualified to do business and is in good standing in each jurisdiction in which the transaction of
its business makes such qualification necessary.

Section 5.2 Authorization and Consent. The execution, delivery and performance by
Borrower of the Loan Documents to which it is or is to be a party have been duly authorized by all
required corporate or limited liability company action and do not and will not (i) require any
consent or approval of the stockholders or members of Borrower, (ii) violate any provisions of any
federal, state or local law, rule, regulation, order, writ, judgment, injunction, decree,
determination or award presently in effect having applicability to Borrower or of the charter,
articles of incorporation or organization, operating agreement or bylaws of Borrower, (iii) result
in a breach of or constitute a default under any indenture or loan or credit agreement, or any

 

 

FORM 6281 (6-2006)

Page 14 of 39

39

other agreement, lease or instrument to which Borrower is a party or by which it or its properties
may be bound or affected or (iv) result in, or require, the creation or imposition of any mortgage,
deed of trust, pledge, lien, security interest or other charge or encumbrance of any nature (other
than as created by the Collateral Agreements — defined?) upon or with respect to any of the
properties now owned or hereafter acquired by Borrower, and Borrower is not in default under any
such law, rule, regulation, order, writ, judgment, injunction, decree, determination or award or
any such indenture, agreement, lease or instrument.

Section 5.3 Binding Agreement. Each of the Loan Documents to which Borrower is a party is
a legal, valid and binding obligation of Borrower, enforceable in accordance with its terms,
subject only to limitations on enforceability imposed by applicable bankruptcy, insolvency,
reorganization, moratorium or similar laws affecting creditors’ rights generally and by general
principles of equity.

Section 5.4 Compliance with Laws. Borrower is in compliance in all material respects with
all federal, state and local laws, rules, regulations, ordinances, codes and orders, including,
without limitation, ERISA, all Environmental Laws, all licensing laws and has filed all federal,
state and local tax returns and has paid all federal, state and local taxes, assessments and
governmental charges imposed upon it or upon its property, except to the extent the same are
contested in good faith and by appropriate proceedings and for which adequate reserves have been
established, and Borrower has no knowledge of any deficiency or additional assessment in connection
therewith.

Section 5.5 Litigation. There is no pending or threatened legal or governmental actions,
proceedings or investigations to which Borrower is a party or to which any property of Borrower is
subject, which may result in a Material Adverse Effect, except as previously disclosed to Lender in
writing.

Section 5.6 Financial Statements. All financial statements, information and other data
which may have been or which may hereafter be submitted by the Borrower to the Lender are true,
accurate and correct and have been or will be prepared in accordance with GAAP consistently applied
or by other method acceptable to Lender and accurately represent the financial condition or, as applicable, the other information disclosed therein.
Since the most recent submission of such financial information or data to the Lender, the Borrower
represents and warrants that no Material Adverse Effect has occurred.

Section 5.7 Assets. Borrower has good and marketable title to and is the record and
beneficial owner of all the Collateral covered by the Collateral Agreements to which Borrower is or
is to be a party, free and clear of all mortgages, deeds of trust, pledges, liens, security
interests and other charges or encumbrances, except for (i) those created by the Collateral
Agreements [?Loan Documents?], and (ii) Permitted Liens, and all such Collateral is in all
material respects in good order and repair (ordinary wear and tear excepted) and covered by the
insurance required under Section 6.5.

Section 5.8 ERISA. If the Borrower has a pension, profit sharing or retirement plan
subject to ERISA, such Plan is in compliance in all material respects with the applicable
provisions of ERISA, the Code and other federal or state law. Each Plan which is intended to
qualify under Section 401(a) of the Code has received a favorable determination letter from the IRS
and to the best knowledge of the Borrower, nothing has occurred which would cause the loss of such
qualification. The Borrower and each ERISA Affiliate has made all required contributions to any
Plan subject to Section 4.12 of the Code, and no application for a funding waiver or an extension
of any amortization period pursuant to Section 4.12 of the Code has been made with respect to any
Plan.

There are no pending or threatened claims, actions or lawsuits, or action by any Governmental
Authority with respect to any Plan, which has resulted or could reasonably be expected to result in
a Material Adverse Effect. There has been no prohibited transaction or violation of the fiduciary
responsibility rules with respect to any Plan, which has resulted or could reasonably be expected
to result in a Material Adverse Effect and no ERISA Event has occurred or is reasonably expected to
occur that, when taken together with all other such ERISA Events for which liability is reasonably
expected to occur, could reasonably be expected to result in a Material Adverse Effect

Section 5.9 Environmental Compliance. All known sources of existing or potential
environmental contamination on or near any property owned or operated by Borrower has been fully
disclosed to Lender; the operations of the Borrower comply in all material respects, and during the
term of this Agreement will at all times comply in all material respects, with all environmental
laws; the Borrower has obtained all licenses, permits, authorizations and registrations required
under any environmental law and necessary for its ordinary course operations, all such
environmental permits are in good standing, and the Borrower is in compliance with all material
terms and conditions of such environmental permits; neither the Borrower nor any of its present
property or operations is subject to any outstanding written order from or agreement

 

 

FORM 6281 (6-2006)

Page 15 of 39

39

with any governmental authority or subject to any judicial or docketed administrative proceeding, respecting
any environmental law, environmental claim or hazardous material; there are no hazardous materials
or other conditions or circumstances existing, or arising from operations prior to the date of this
Agreement, with respect to any property of the Borrower that would reasonably be expected to give
rise to material environmental claims. In addition, Borrower shall hold Lender harmless from any
liability for environmental waste or contamination on any property owned or operated by Borrower or
liability imposed as a consequence by reason of Borrower’s activities and will indemnify Lender
against all claims, losses, liabilities, and expenses incurred by Lender as a result thereof. This
covenant will survive cancellation or termination of this Agreement.

Section 5.10 No Default. Borrower is not in an Event of Default in the payment of any
indebtedness representing any borrowing or financing or is in an Event of Default, or aware of any
third party default, in respect to the performance, observance or fulfillment of any of the
obligations, covenants or conditions contained in any agreement to which Borrower is a party.

Section 5.11 Receipt and Verification. Borrower has received a copy of the “Customer
Information and Disclosure Handbook” and that all the information provided by Borrower to Lender is
true and correct.

Section 5.12 Margin Stock. Borrower is not engaged in the business of extending credit
for the purpose of purchasing or carrying margin stock (within the meaning of Regulation U of the
Board of Governors of the Federal Reserve System), and no proceeds of any Advance will be used to
purchase or carry any margin stock or to extend credit to others for the purpose of purchasing or
carrying any margin stock.

Section 5.13 Security Interest. Each of the Collateral Agreements constitutes a valid and
perfected first priority security interest and lien, in and to the Collateral purported to be
covered by each thereof, except as otherwise provided therein, enforceable against all third
parties in all jurisdictions securing the payment of all obligations purported to be secured
thereby (except for Permitted Liens), and all action required to perfect fully such security
interests and liens so constituted have been taken and completed.

Section 5.14 Contractual Restrictions. Borrower is not a party to any indenture, loan or
credit agreement or any lease or other agreement or instrument or subject to any charter or
corporate restriction, which would result in a Material Adverse Effect.

Section 5.15 Approvals and Licenses. Borrower possesses all the franchises, permits and
licenses necessary or required in the conduct of its business, and the same are valid, binding and
enforceable and all authorizations, consents, approvals or licenses of, or filings or registrations
with, any court or governmental department, commission, board, bureau, agency or instrumentality,
domestic or foreign, or any specifically granted exemptions from any of the foregoing, necessary to
the valid execution, delivery or performance by Borrower of this Agreement and the Loan Documents
to which it is or is to be a party have been obtained and are in full force and effect.

Section 5.16 No Untrue Statements. No information, exhibit, schedule or report furnished
by Borrower to Lenders contained or contains any untrue statement of material fact or omitted or
omits to state any material fact necessary to make the statements contained therein, in light of
the circumstances under which such statements are made, misleading.

Section 5.17 Solvency. Borrower is and, after consummation of the transactions
contemplated by this Agreement and the other Loan Documents, shall be, solvent. For the purposes
of this paragraph, “solvent” means (i) the fair value of the property of Borrower is greater than
the total amount of liabilities, including contingent liabilities of Borrower, (ii) the amount that
will be required to pay the probable liabilities of Borrower on its debts as they become absolute
and matured shall not be greater than the fair value of the assets of Borrower at such time, (iii)
Borrower is able to realize upon its assets and pay its debts and other liabilities, contingent
obligations and other commitments as they mature in the normal course of business, (iv) Borrower
does not intend to, and does not believe it shall, incur debts or liabilities beyond its ability to
pay as such debts and liabilities mature and (v) Borrower is not engaged in a business or a
transaction, and is not about to engage in a business or a transaction, for which Borrower’s
property would constitute unreasonably small capital after giving due consideration to prevailing
practices in the industry in which Borrower is engaged. In computing the amount of any contingent
liability at any time, it is intended that such liability shall be computed at the amount that, in
light of all the facts and circumstances existing at such time, represents the amount that might
reasonably be expected to become an actual or matured liability.

 

 

FORM 6281 (6-2006)

Page 16 of 39

39

Section 5.18 Taxes. Borrower and each other Person for whose taxes Borrower could
become liable have timely filed or caused to be filed all federal income tax returns and all other
material tax returns that are required to be filed by any of them, and have paid all taxes shown to
be due and payable (or with respect to real estate taxes, have paid all taxes prior to the time the
same become delinquent) on such returns or on any assessments made against it or its property and
all other taxes, fees or other charges imposed on it or any of its property by any governmental
authority, except (a) to the extent the failure to do so would not have a Material Adverse Effect
or (b) where the same are currently being contested in good faith by appropriate proceedings and
for which Borrower has set aside adequate reserves on its books. The charges, accruals and
reserves on the books of Borrower in respect of such taxes are adequate, and no tax liabilities
that could be materially in excess of the amount so provided are anticipated.

Section 5.19 Projections. As of the Closing Date, the projections fairly present
Borrower’s reasonable forecast of the results of operations and changes in cash flows for the
periods covered thereby, based on the assumptions set forth therein, which assumptions are
reasonable based on historical experience and presently known facts. Since the date of such
projections, there have been no changes with respect to Borrower or its Subsidiaries which could
reasonably be expected to result in, singly or in the aggregate, a material discrepancy between
such projections and Borrower’s actual results for the periods stated.

Section 5.20 Material Contracts. As of the Closing Date, there are no Material Contracts
other than those which have been disclosed to Lender and subject to assignment to Lender.

ARTICLE 6 — AFFIRMATIVE COVENANTS

The Borrower covenants and agrees that during the term of this Agreement and so long as any
Indebtedness remains unpaid or any amounts drawn hereunder remain unreimbursed, each such Borrower
shall comply with the following requirements:

Section 6.1 Preservation of Existence. Borrower shall maintain and preserve its existence
and good standing in the jurisdiction in which such qualification and good standing are necessary
in order for Borrower to lawfully conduct its business and own its property in said jurisdiction.

Section 6.2 Compliance with Laws. Borrower shall comply with all laws, rules, regulations
and orders of any Government Authority applicable to it or its property, such compliance to
include, without limitation, ERISA and Environmental Laws and paying before the same become
delinquent all taxes, assessments and governmental charges imposed upon it or upon its property,
unless contested in good faith.

Section 6.3 Books and Records. Borrower shall at all times keep proper books of record
and account in which correct and complete entries shall be made of all its dealings, in accordance
with generally accepted accounting principles or other method acceptable to Lender.

Section 6.4 Inspection of Properties and Books. Borrower shall, upon reasonable notice
and at any reasonable time and from time to time, permit Lender, upon request, to visit and inspect
any of the Collateral or properties of Borrower and to examine the books, accounts and other
records of the Borrower and to take abstracts therefrom and to discuss the affairs, finances, loans
and accounts of the Borrower with Borrower’s representatives. If the Borrower shall maintain any
records in the possession of a third party, the Borrower authorizes such third party to provide
Lender with copies of any records which it may request.

Section 6.5 Maintenance of Property; Insurance. Borrower shall maintain all of its
properties necessary or useful in its business in good condition, repair and working order, normal
wear and tear excepted, and shall maintain insurance with financially sound and reputable insurance
companies in such amounts and covering such risks as are usually carried by companies engaged in
the same or a similar business and similarly situated. Borrower shall maintain casualty insurance
on the Collateral for not less than its full replacement value and shall name Lender as mortgagee
on all casualty insurance and shall provide Lender with evidence of such insurance upon request.
Except for insurance proceeds from losses of less than $100,000 (which shall be paid directly to
Borrower), all proceeds of any insurance will be held by Lender as additional collateral and shall
be used to pay for reconstruction, repair, or replacement of the Collateral, or applied to payment
of the Loans. In addition, to the extent that any real property interests which constitute a part
of the Collateral lie within a designated flood plain, Borrower must maintain flood insurance with
respect to such real property interest. In addition, Borrower shall maintain commercial general
liability insurance, business automobile liability insurance, workers’ compensation insurance,
business interruption insurance of 3 months of projected expenses for the

 

 

FORM 6281 (6-2006)

Page 17 of 39

39

Facility, directors and officers liability insurance, and such other insurance coverages as
shall be required by Lender, all with terms and conditions satisfactory to Lender. Insurance will
be obtained from companies reasonably satisfactory to Lender and said policies shall name Lender as
an additional insured. The policies shall provide that there be no cancellation or modification
without 30 days advance notification to Lender.

Section 6.6 Notice of Material Events. Borrower agrees to give Lender prompt written
notice of any and all (i) Events of Default or Potential Default; (ii) litigation, arbitration or
administrative proceedings to which the Borrower is a party and, if adversely determined, could
reasonably be expected to result in a Material Adverse Effect; (iii) default under any note,
indenture, loan agreement, mortgage, lease, contract, deed or other similar agreement to which
Borrower is a party or by which Borrower is bound, which relates to borrowed money, or of any other
default under any other note, indenture, loan agreement, mortgage, lease, contract, deed or other
similar agreement to which any Borrower is a party or by which Borrower is bound if such other
default may result in a Material Adverse Effect; (iv) violation of environmental laws or permits
and (v) other development that results in, or could reasonably be expected to result in, a Material
Adverse Effect. Each notice delivered under this Section shall be accompanied by a statement of an
officer of the Borrower setting forth the details of the event or development requiring such notice
and any action taken or proposed to be taken with respect thereto.

Section 6.7 Reports. Borrower shall provide to Lender the following financial reports and
such other reports with respect to the financial condition and operations of Borrower as Lender may
from time to time reasonably request:

Section 6.7.1 Annual Financial Statements and Budget Projections. As soon as
available, but in no event later than 120 days after the end of the fiscal year of Borrower,
an audit report in accordance with GAAP and prepared by an accountant acceptable to Lender
for such year and accompanying financial statements (including all footnotes thereto)
including a consolidated balance sheet, a consolidated statement of income and retained
earnings and, within 30 days prior to the end of the fiscal year of Borrower, a pro-forma
budget projection, including proposed capital expenditures, for the next fiscal year in form
and content acceptable to Lender, both of which shall be an Event of Default if not provided
within 30 days after said report and projection is due.

Section 6.7.2 Periodic Financial Statements. As soon as available, beginning with
the month in which ethanol production commences, and in no event later than 30 days after the
end of each month thereafter (excluding the last month of Borrower’s fiscal year) a
consolidated balance and consolidated income statement and production report of all
Borrower’s production of ethanol for that month and for year-to-date since the last fiscal
year end, such report certified complete and correct from a source acceptable to Lender,
which shall be an Event of Default if not provided within 30 days after said report is due.

Section 6.7.3 Additional Information. Such other information respecting the
condition or operations, financial or otherwise of Borrower or such other information
relating to Borrower as any Lender may from time to time reasonably request.

Section 6.8 Account Authorization. Borrower will require the financial or other
institutions with which it maintains or has maintained depository and operating accounts to
promptly provide such information concerning the Borrower, its financial condition and any
transactions as Lender may from time to time request. Borrower hereby authorizes such institutions
to directly provide to Lender such information as Lender may request.

Section 6.9 Execution of Supplemental Instruments. Execute and deliver to Lender from
time to time, upon demand, such supplemental agreements, statements, transfers, assignments,
authorizations to release information, or documents relating to the Collateral, and such other
instruments or documents as Lender may request, in order that the full intent of this Agreement may
be carried into effect.

Section 6.10 Financial Covenants. Borrower agrees to maintain sufficient capital
resources, as determined by Lender’s market valuation of Borrower’s assets and full disclosure of
Borrower’s liabilities such as to maintain the following financial covenants. In the event that
Borrower fails to comply with said covenants and said failure continues for 30 days after
notification from Lender, Lender may deem said failure an Event of Default.

Section 6.10.1 Working Capital. Beginning with the month in which Substantial
Completion occurs, Borrower agrees to maintain working capital (current assets, plus the
unadvanced portion of Loan Facility B and Facility C, minus current liabilities) of not less
than $5,000,000.00, increasing to $5,500,000.00 at fiscal year end 2008 and thereafter.

 

 

FORM 6281 (6-2006)

Page 18 of 39

39

Section 6.10.2 Debt Coverage Ratio. Beginning with the first fiscal year end
that occurs over six months after Substantial Completion and annually thereafter, Borrower
agrees to maintain a Debt Coverage Ratio, defined as net income plus depreciation and
amortization minus extraordinary gain(loss) minus after tax income(expense) minus gain(loss)
on assets sale to current principal of long-term debt, of not less than 1.50:1.00 .

Section 6.10.3 Tangible Net Worth. Beginning with the month in which Substantial
Completion occurs, Borrower agrees to maintain minimum Tangible Net Worth (total tangible
assets minus total liabilities) of not less than $49,000,000.00, increasing to not less than
$50,000,000.00 at fiscal year end 2008 and increasing to not less than $52,000,000.00 at
fiscal year end 2009 and thereafter.

Section 6.11 Compliance Certificate. Beginning with last day of the month in which
ethanol production commences, Borrower agrees to provide Lender with a Compliance Certificate
showing or certifying compliance with the aforesaid reporting and financial requirements and as of
the last day of each month (Reporting Period) thereafter, in form and content acceptable to Lender.
Such Certificate shall be provided to Lender within 20 days following the end of each Reporting
Period, and in default after 30 days.

Section 6.12 Construction Covenants.

Section 6.12.1 Insurance/Bonds. In addition to the insurance requirements set forth
in this Agreement, Borrower agrees to procure and maintain at Borrower’s expense insurance
coverage from reputable companies for builder’s risk, fire and extended coverage in an amount
equal to the completed value of the Facility with Lender named as mortgagee together with
such other property insurance on Borrower’s business as Lender may require; and public
liability coverage and insurance against loss under any workman’s compensation laws. Proof of
insurance in compliance with this provision will be provided Lender during the term of this
Agreement as Lender may require.

Borrower shall retain the services of an inspecting engineer to monitor comparisons with
reports and applications for payment received from the general contractor and shall also
require the project design engineer to procure a professional liability policy insuring said
engineer and shall furnish Lender a copy of said policy [? Will Fagen do this?].

Section 6.12.2 Compliance with Law. Borrower will obtain and keep in force all
permits or certificates required for completion of the work under the Construction Contract,
and will comply with all applicable zoning, building or other laws or regulations applicable
to the Facility and its operations, and will provide Lender with proof of compliance prior to
construction and thereafter during the term of this Agreement as Lender may require.

Section 6.12.3 Construction Contract. Borrower agrees to bring the Facility into
production no later than December 1, 2007 and agrees to complete construction according to
the plans and specifications furnished to Lender and pursuant to the Construction Contract no
later than April 1, 2008. Borrower will obtain Lender’s prior written approval of any change
to the plans and specifications that might adversely affect Lender’s security or any change
to the terms and conditions of the Construction Contract that exceeds $3,600,000.00 or
exceeds Borrower’s budgeted costs for construction of the Facility, as approved by Lender.
Borrower will also obtain all approvals of any changes in plans, specifications, work,
materials or contracts that are required by law or any covenants or agreements relating to
the Facility. The project budget, plans and specifications, cost breakdowns, disbursement
schedules, completion reports and other construction information currently or in the future
submitted to Lender fairly and accurately present the matters contained therein as of the
date thereof, there are no omissions from the information so submitted or other facts and
circumstances not reflected in such information which are or may be material and there have
been no material or adverse changes in the information so supplied without notice of the same
by Borrower to Lender.

Borrower will furnish to Lender, at Lender’s request, correct lists of all contractors,
subcontractors and suppliers employed in connection with construction of the Facility and
true and correct copies of all executed contracts and subcontracts.

Section 6.12.4 During Construction Draws. Lender, Lender’s inspecting engineer and
Disbursing Agent shall have the right to inspect the construction work at all reasonable
times. Any inspection of the work, books, or the review, examination, or approval of any
contract, document, insurance policy or other matters shall be for the sole

 

 

FORM 6281 (6-2006)

Page 19 of 39

39

benefit of Lender and not for the benefit of the Borrower, contractor, or others.
Lender is under no duty to supervise or inspect construction or examine any books and
records. No default of Borrower will be waived by any inspection by Lender. In no event will
any inspection by Lender be a representation that there has been or will be compliance with
the plans or specifications or that the construction is free from defective materials or
workmanship.

(a) Disbursements for construction shall be made at Borrower’s request no more frequently
than monthly solely to pay costs incurred under the Construction Contract for work completed
under the terms of said Construction Contract and to the extent such costs are in conformity
with the cost estimate provided to Lender. Borrower shall be required, under the terms of
this Agreement, to pay certain of the initial costs of construction before any disbursements
are made by Lender for the balance of the costs of construction. An Advance for construction
and non-construction purposes until Substantial Completion, pursuant to a Draw Request, shall
be made in accordance with the terms and conditions of a disbursing agreement in a form
acceptable to Lender (the “Disbursing Agreement”).

(b) Each Advance on a Loan shall be made only upon Borrower’s written (or telephonic notice
promptly confirmed in writing) request to Disbursing Agent and Lender substantially in the
form of Exhibit ‘C’ attached hereto (“Draw Request”). Each Draw Request will
constitute a certification, representation and warranty that the conditions precedent for an
Advance under this Agreement have been satisfied and that no Material Contract has been
entered into other than those which are subject to a collateral assignment in favor of Lender
or which Lender has agreed in writing that no collateral assignment will be required.

(c) Disbursement shall be made only if this documentation and any inspection shows that
construction is proceeding in accordance with the plans and specifications approved by Lender
and the Borrower is not otherwise in default. If there is a material deviation from the
Construction Contract, a deficiency in the materials or workmanship, a termination or
abandonment of the contract, an uninsured loss or damage to the completed work or failure to
comply with the terms of this Agreement, Lender may declare default and among other remedies,
refuse to make further disbursement until default is cured. The making of disbursement prior
to fulfillment of any or all of these loan conditions, however, shall not be construed as a
waiver of these conditions. Lender reserves the right to require their fulfillment prior to
making any subsequent disbursements. Final disbursement of the loan shall only be made when
the Construction Contract is fully completed and upon receipt of a certificate signed by the
Borrower and contractor certifying that all work has been completed satisfactorily and in
accordance with the Construction Contract (Completion Certificate). Lender will retain the
sum of not less than $3,291,309.00 pending satisfaction of the construction lending
conditions set forth herein.

(d) If Lender reasonably determines at any time that the amount of the undisbursed Loan
proceeds will not be sufficient to pay for all costs required to complete acquisition and
construction of the Facility in accordance with the approved plans and specifications,
whether that deficiency is attributable to changes in the construction work, in the plans and
specifications, or to any other cause, Lender may demand in writing that the Borrower deposit
with Lender non-interest bearing funds equal to the amount of the shortage reasonably
determined by Lender. The Borrower must then deposit the required funds with lender within
ten (10) days after the date of Lender’s written demand. No further disbursements need be
made by Lender until those funds are deposited by the Borrower with Lender. Whenever Lender
has any of those funds on deposit, all disbursements will be considered to be made by Lender
first from those funds until they are exhausted.

Section 6.12.5 Post-Construction Draws. (b) Each Advance on a Loan following
Substantial Completion shall be made only upon Borrower’s written (or telephonic notice
promptly confirmed in writing) request to Lender substantially in the form of Exhibit ‘C’
attached hereto (“Draw Request”) not later than 1:00 P.M. (Omaha time) on any Business
Day from disbursal of immediately available funds that same day. Any request for Advances
received after 1:00 P.M. may be made on the next Business Day. Each Draw Request will
constitute a certification, representation and warranty that the conditions precedent for an
Advance under this Agreement have been satisfied and that no Material Contract has been
entered into other than those which are subject to a collateral assignment in favor of Lender
or which Lender has agreed in writing that no collateral assignment will be required. After
Substantial Completion, the principal amount of each Draw Request must be at least
$100,000.00 and in multiples of $100,000.00.

 

 

FORM 6281 (6-2006)

Page 20 of 39

39

Section 6.12.6 Construction Cost Reconciliation. Until Substantial Completion,
as soon as available, but in no event later than 30 days after the end of each month,
Borrower agrees to provide a reconciliation of actual versus projected construction costs of
the Facility for that month and for year-to-date.

Section 6.12.7 No Third Party Right. This agreement is between Borrower and Lender
only and does not create any rights inuring to the benefit of a contractor, subcontractor or
any other third party.

Section 6.12.8 Assignment of Construction Contract. Borrower assigns and grants to
Lender, as additional security for the loan, Borrower’s interest in the Construction Contract
and any other contracts, drawings, plans, specifications or permits pertinent to the
construction of the Facility. In the event of Borrower default on the Loans, Borrower agrees
that Lender may elect to complete construction under the terms of said Construction Contract,
although Lender shall not be bound by said contract to do so, or may contract to employ other
parties to proceed with the work until completed. If Lender elects to complete the Facility,
Borrower agrees not to hold Lender liable for the manner or quality of said construction.
Such disbursements for completion after Borrower default shall be considered to have been
disbursed to the Borrower and will be secured by the trust deed executed in connection with
this Agreement. If such disbursements exceed the Maximum Principal Balance of the Loans,
they will be considered to be an additional loan to the Borrower, bearing interest at the
highest rate provided in the note.

Section 6.12.9 Indemnification. In consideration for said Loans, Borrower agrees to
indemnify Lender and hold it harmless from any losses, costs or damages, including attorneys’
fees, arising by reason of defective workmanship or materials occurring in the construction
or operation of the Facility, or occurring by reason of any breach or default of this
Agreement or the Construction Contract. The provisions of this Section will survive the
termination of this Agreement.

Section 6.12.10 Assignment of Material Contracts. Borrower agrees to notify Lender
of the existence of any Material Contract promptly upon entering into the same. Borrower
agrees to assign to Lender all Material Contracts and take such other actions as Lender
requests to perfect Lender’s security interest in Borrower’s rights under such Material
Contracts

Section 6.12.11 Grain Hedging. Borrower agrees to execute a Security Agreement and
Assignment of Hedging Account on a form provided or approved by Lender to be acknowledged by
all brokers involved in Borrower’s hedging program.

Section 6.12.12 Account Control Agreements. Borrower agrees to notify Lender of any
new Investment Account and/or hedging account promptly upon creating the same. Borrower
agrees to assign the Lender all investment accounts and hedging accounts, and take such other
actions as Lender requests to perfect Lender’s security interest in Borrower’s right to the
accounts.

ARTICLE 7 — NEGATIVE COVENANTS

The Borrower covenants and agrees that as long as the Loan remains unpaid, they will comply with
the following requirements, unless the Lender shall otherwise consent in writing.

Section 7.1 No Material Change. The Borrower will not adopt any material change in
accounting method or principles, unless approved by Lender; will not adopt, permit or consent to
any change in its fiscal year; and will not enter into any contract, agreement or transaction
affecting the Collateral or the Loan which would have a Material Adverse Effect.

Section 7.2 No Other Business. The Borrower will not engage in any material respects in
any business activity or operations materially different from that presently engaged in by the
Borrower and will not purchase, lease or otherwise acquire assets not related to or used in its
business.

Section 7.3 Transactions with Subsidiaries. Borrower will not purchase, acquire, provide,
or sell any equipment, other personal property, real property or services from or to any
Subsidiary, except in the ordinary course and pursuant to the reasonable requirements of Borrower’s
business.

Section 7.4 Transactions with Affiliates. The Borrower will not enter into any
transaction, including without limitation, the purchase, sale, lease or exchange of any property,
or the rendering of any service, with any Affiliate of the Borrower, except in the ordinary course
of and pursuant to the reasonable requirements of the Borrower’s business and upon fair

 

 

FORM 6281 (6-2006)

Page 21 of 39

39

and reasonable terms no less favorable to the Borrower than would be obtained in a comparable
arms-length transaction with a person not an Affiliate of the Borrower.

Section 7.5 Consolidation and Merger. The Borrower will not, and will not permit any
Subsidiary to, consolidate with or merge with any entity, or acquire all or substantially all of
the assets of any person or entity, nor shall Borrower change its business form, provided that
Borrower or any Subsidiary may acquire the assets of any person or entity if there has been no
Event of Default or Potential Default and shall not be after giving effect to said acquisition, and
that said acquisition shall not result in a Material Adverse Effect .

Section 7.6 Transfer of Assets. The Borrower will not sell, assign (by operation of law
or otherwise) transfer, exchange, lease or otherwise dispose of any of the Collateral, nor will
Borrower deliver actual or constructive possession of the Collateral to any other person or entity,
other than in the ordinary course of business as presently conducted and at fair market value and
which are either replaced or are no longer necessary or useful for the business conducted by
Borrower.

Section 7.7 Liens; Negative Pledge. The Borrower will not create, incur, assume or permit
to exist any lien, mortgage, pledge, charge or other encumbrance on, or any security interest in,
any of its real or personal properties, except liens in favor of Lender; liens existing prior to
the date of this Agreement that have been disclosed in writing to Lender; liens for taxes and other
governmental charges which are not delinquent or the validity of which is being contested in good
faith; liens of carriers, warehousemen, mechanics and other like liens arising in the ordinary
course of business; and except Permitted Liens.

Section 7.8 Indebtedness. The Borrower will not create, incur, assume, guaranty, permit
or suffer to exist any indebtedness or otherwise become liable with respect to the obligations or
liabilities of any person or entity except: indebtedness of Borrower arising under this Credit
Agreement; indebtedness existing prior to the date of this Agreement that has been disclosed in
writing to Lender; debt subordinated in form and substance reasonably acceptable to Lender; trade
payables of Borrower incurred in the ordinary course of business; and except such additional debt
obligations or annual capitalized lease payments as may be listed herein or which do not exceed in
the aggregate the sum of $500,000.00.

Section 7.9 Loans, Advances and Guarantees. The Borrower will not make, or permit any
Subsidiary to make, any loans or advances to, or guarantees of, or otherwise become liable, or
permit any Subsidiary to become liable, with respect to (other than guarantees by endorsement of
negotiable instruments for deposit or collection or similar transactions in the ordinary course of
business), or permit to exist, or allow any Subsidiary to permit to exist, any loans or advances
to, or such guarantees or other such liabilities with respect to, any Person, except: loans,
advances and guarantees existing as of the date hereof and listed on Schedule 7.9; and trade credit
extended in the ordinary course of business.

Section 7.10 Subordinated Debt. The Borrower will not make payments on account of any
existing subordinated debt and shall not incur any additional subordinated debt except to the
extent permissible under the agreement by which such subordinated debt is subordinated to the Loan.
Borrower shall not amend, supplement, or otherwise modify any provisions of the subordinated debt
agreement, and shall not refinance any portion of the subordinated debt, except on terms no less
favorable to Borrower and Lender.

Section 7.11 Capital Spending. Other than for construction of the Facility, Borrower will
not make Capital Expenditures during any fiscal year from any source of funds available which
exceed $500,000.00 in the aggregate.

Section 7.12 Distribution and Withdrawals. Borrower will not distribute any profits, make
any loans, declare or pay any dividends, distribute earnings, allow any draws, or make other
distributions to its members of Borrower or apply any assets to the redemption, retirement,
purchase or other acquisition of any such equity interests; however if no Event of Default or
Potential Default shall exist following completion of Borrower’s audit, Borrower may pay dividends
and distributions within 120 days following the close of the prior fiscal year, not to exceed 40%
of the net profit for said previous fiscal year, so long as Borrower remains in compliance with
required financial covenants on a post distribution basis. For fiscal years ending 2008 and
thereafter, Borrower may pay dividends and distributions which exceed 40% of the net profit if
Borrower has made the Excess Cash Flow payment for said fiscal year and so long as Borrower remains
in compliance with required financial covenants on a post distribution basis.

 

 

FORM 6281 (6-2006)

Page 22 of 39

39

Section 7.13 No Change in Management, Ownership or Control. Borrower will not make
any change in present Control of its business or of the Collateral; provided, however, this Section
7.13 does not in any manner apply to the election of the board of directors of the Borrower as
provided for in the Operating Agreement of Borrower.

Section 7.14 Deposit and Investment Accounts. Borrower will not maintain, deposit or
invest funds into any Deposit Account or Investment Account other than those listed on Schedule
7.14.

Section 7.15 Investments. Borrower will not purchase, hold or acquire any common stock,
evidence of indebtedness or other securities (including any option, warrant, or other right to
acquire any of the foregoing) of, make or permit to exist any loans or advances to, guarantee any
obligations of, or make or permit to exist any investment or any other interest in, any other
Person (all of the foregoing being collectively called “Investments”), or purchase or otherwise
acquire (in one transaction or a series of transactions) any assets of any other Person that
constitute a business unit, or create or form any Subsidiary, except:

	 	(a)	 	Investments (other than Permitted Investments) existing on the date hereof and
set forth on Schedule 7.15;
	 
	 	(b)	 	Permitted Investments in which Lender maintains a first priority, perfected security
interest therein;
	 
	 	(c)	 	loans or advances to employees, officers or directors of Borrower in the ordinary
course of business for travel, relocation and related expenses; provided,
however, that the aggregate amount of all such loans and advances does not exceed
$100,000 at any time;
	 
	 	(d)	 	Investments in other business organizations whose primary business is the
production of ethanol and byproducts related thereto and in which Lender maintains a
first priority, perfected security interest in such Investments; provided, at the time
any such Investment is made, the aggregate book value of the sum of all such Investments
may not, without the prior written consent of Lender, exceed five percent (5.0%) of the
net worth of Borrower; and
	 
	 	(e)	 	other Investments which in the aggregate do not exceed $200,000.00 in any fiscal
year of Borrower.

Section 7.16 Amendments. Borrower will not amend or terminate their Articles of
Organization, Operating Agreement, or Material Contracts, without Lender’s prior written consent,
which consent shall not be unreasonably withheld.

Section 7.17 Construction. Borrower will not become a party to any contract for the
performance of any work related to the project or for the supplying of any labor, materials or
services for the construction of improvements that would have the effect of increasing the costs of
the project more than $3,600,000.00 (in the aggregate with previous such cost increases) above
those set forth in the sworn construction cost statement, except in such amounts and upon such
terms and with such parties as are approved in writing by Lender (which approval will not be
unreasonably withheld). No approval by Lender of any contract or change order will make Lander
responsible for the adequacy, form or content of such contract or change order. Borrower will
expeditiously complete and fully pay for the development and construction of the project in a good
and workmanlike manner and in accordance with the contracts, subcontracts and construction plans
submitted to Lender and in compliance with all applicable requirements of all governmental
authorities, and any covenants, conditions, restrictions and reservations applicable thereto, so
that Substantial Completion occurs on or before the required completion date. Borrower assumes
full responsibility for the compliance of the construction plans and the project with all
requirements of all governmental authorities and with sound building and engineering practices, and
notwithstanding any approvals by Lender, Lender has no obligation or responsibility whatsoever for
the Construction Plans or any other matter incident to the project or construction related to the
project. Borrower will correct or cause to be corrected (a) any defect in improvements related to
the project, (b) any departure from the construction plans or any requirements of any governmental
authorities, and (c) any encroachment by any part of any structure located on the real estate on
any building line, easement, property line or restricted area. Borrower will cause all roads
necessary for the efficient operation of the plant contemplated by the project to be completed and
dedicated (if dedication thereof is required by any governmental authority), the bearing capacity
of the soil on the real estate to be made sufficient to support all improvements thereon, and
sufficient local utilities to be made available to the project and installed at costs (if any) set
out in the sworn construction cost statement, on or before the required completion date. No work
may be performed pursuant to any change order or pending change order to the construction plans
prior to delivery thereof to Lender.

ARTICLE 8 — EVENTS OF DEFAULT

 

 

FORM 6281 (6-2006)

Page 23 of 39

39

Section 8.1 Events of Default. The occurrence of any of the following events shall
constitute an event of default (“Event of Default”) hereunder:

Section 8.1.1 Failure to Make Payments. Borrower shall fail to pay, in accordance
with the terms of this Agreement, (i) any principal on any Loan on the date that such is due,
(ii) any interest on such Loan within 5 days from the date that such is due, or (iii) any fee
or other cost owing to Lender under the Agreement within 15 days after the date that such sum
is due.

Section 8.1.2 Breach of Warranty or Representation. Any representation or warranty
made by Borrower under or in connection with this Agreement or any financial statement given
by Borrower, which shall prove to have been materially misrepresented on or as of the date
made or given.

Section 8.1.3 Insolvency. Borrower shall: (i) become insolvent or be unable to pay
its debts as they mature; (ii) make an assignment for the benefit of creditors or to an agent
authorized to liquidate any substantial amount of its properties and assets; (iii) file a
voluntary petition in bankruptcy or seeking reorganization or to effect a plan or other
arrangement with creditors; (iv) file an answer admitting the material allegations of an
involuntary petition relating to bankruptcy or reorganization or join in any such petition;
(v) become or be adjudicated a bankrupt; or (vi) apply for or consent to the appointment of,
or consent that an order be made, appointing any receiver, custodian or trustee, for itself
or any of its properties, assets or businesses, or (vii) have an involuntary bankruptcy
petition filed against Borrower, and such petition remains undismissed for more than 30 days.

Section 8.1.4 Execution. Any writ of execution or attachment or any judgment lien
shall be issued against any property of the Borrower and shall not be discharged or bonded
against or released within 30 days after the issuance or attachment of such writ or lien.

Section 8.1.5 Suspension. Borrower shall voluntarily suspend, without just cause,
the transaction of business or allow to be suspended, terminated, revoked or expired any
permit, license or approval of any governmental body necessary to conduct the Borrower’s
business resulting in a Material Adverse Effect.

Section 8.1.6 Due on Sale. Except as permitted under Article 4 herein, there shall
occur, without Lender’s prior written consent, the sale, transfer or further encumbrance of
any material item of Collateral, other than in the ordinary course of business.

Section 8.1.7 Material Adverse Change. If there occurs a Material Adverse Effect in
the Borrower’s business or financial condition that would likely cause an event of Default
within the following 30 days, or if there is a material impairment of the prospect of
repayment of any portion of the Loan or there is a material impairment of the value or
priority of the Lender’s security interest in the Collateral.

Section 8.1.8 Change in Ownership. There shall occur a change affecting the Control
of the Borrower which shall mean for purposes of this Section 8.1.8 the transfer of a
majority of the outstanding membership interests (units) of the Borrower within a 180 day
period.

Section 8.1.9 Impairment of Collateral. There shall occur any injury or damage to
all or any part of the Collateral or all or any part of the Collateral shall be lost, stolen
or destroyed resulting in a Material Adverse Effect.

Section 8.1.10 Performance Under This Agreement. The Borrower shall fail in any
material respect to perform or observe any other term, covenant or agreement contained in
this Agreement or in any of the Loan Documents or any other document or agreement executed by
Borrower with or in favor of Lender, not specifically mentioned above and capable of being
remedied by Borrower and any such failure shall continue unremedied for more than 30 days
after written notice from the Lender to the Borrower of the existence and character of such
Event of Default.

Section 8.2 Cross Default/Cross Collateralization. The Loans and Loan Documents, as well
as any other contract obligation or Debt Borrower may now or in the future have with Lender, are
expressly cross-defaulted. Declaration of default under any Loan described herein or any other
contract obligation or Debt Borrower may have with Lender or Lender’s Affilitate may, at Lender’s
option, cause all Loans and such other contract obligations to be declared in default,

 

 

FORM 6281 (6-2006)

Page 24 of 39

39

charged interest at the default rate and become immediately due and payable. The Collateral,
whether real or personal property, and whether secured by mortgage, deed of trust, or by security
agreement/financing statement, shall secure payment of all the Loans, or any of them. The Loans
are hereby cross-collateralized and none of the Collateral shall be released until all of said
Loans are paid in full.

Section 8.3 Remedies on Default. Upon the occurrence of any Event of Default, Lender may,
at its sole discretion, do any of the following:

Section 8.3.1 Acceleration. Declare any or all of the Borrower’s Loans, whether
under this Agreement or any other document, instrument or agreement, immediately due and
payable, whether or not otherwise due and payable.

Section 8.3.2 Default Interest. If any principal, interest, or Advance is past due,
regardless of the length of time, or if there is any failure to comply with any covenant,
condition, or agreement contained in this Agreement subject to cure periods, or in any
mortgage, trust deed, security agreement, or other document, given to secure payment of the
Loan, then, at the election of the Lender, all principal, all accrued interest thereon and
all advances will become immediately due and payable without demand and the whole will bear
interest at the Default Rate from and including the date of election to but excluding the
date paid. Any reasonable attorney fees (to the extent allowed by law), costs, or expenses
incurred and advanced by Lender to enforce collection of the Loan will be added to the
principal and bear interest at the Default Rate from the date of advance to but excluding the
date paid. At Lender’s option, any Event of Default may allow Lender to charge interest on
all principal, all accrued interest thereon, and all advances at the Default Rate without
declaring the Loan immediately due and payable.

Section 8.3.3 Cease Extending Credit. Cease making advances or otherwise extending
additional credit to or for the account of the Borrower under this Agreement or under any
other agreement now existing or hereafter entered into between the Borrower and Lender.

Section 8.3.4 Termination. Terminate this Agreement as to any future obligation of
the Lender without affecting the Borrower’s Obligations to the Lender or the Lender’s rights
and remedies under this Agreement or under any other document, instrument or agreement.

Section 8.3.5 Protection of Security Interest. Make additional or protective
advances and do such acts as the Lender, in its sole judgment, considers necessary and
reasonable to protect its security interest or lien in the Collateral. Such additional or
protective advances may be made to protect the Collateral, including but not limited to,
payment of insurance premiums and taxes, as well as payments to protect the Collateral from
claims of other creditors, diminution in value, waste, destruction or abandonment. Such
advances may be added to the Loan and will, at Lender’s option, be immediately due and
payable and bear interest at the Default Rate from the date advanced to but excluding the
date paid. The Borrower hereby irrevocably authorizes the Lender to pay, purchase, contest
or compromise any encumbrance, lien or claim which the Lender, in its sole and reasonable
judgment, deems to be prior or superior to its security interest. Further, the Borrower
hereby agrees to pay to the Lender, upon demand, all expenses (including reasonable
attorney’s fees) incurred in connection with the foregoing.

Section 8.3.6 Foreclosure. Enforce any security interest or lien given or provided
for under this Agreement or under any security agreement, mortgage, deed of trust or other
document, in such manner and such order, as to all or any part of the properties subject to
such security interest or lien, as the Lender, in its sole judgment, deems to be necessary or
appropriate and the Borrower hereby waives any and all rights, obligations or defenses now or
hereafter established by law relating to the foregoing. In the enforcement of its security
interest or lien, the Lender is authorized to enter upon the premises where any Collateral is
located and take possession of the Collateral or any part thereof, together with the
Borrower’s records pertaining thereto, or the Lender may require the records be made
available to the Lender at a place reasonably designated by the Lender. If any part of the
Collateral is accounts receivable, Lender may notify at any time the account debtor to make
payment thereon directly to Lender and may take control of the cash and noncash proceeds of
any such accounts. The Lender may sell the Collateral or any portions thereof, together with
all additions, accessions and accessories thereto, giving only such notices and following
only such procedures as are required by law, at either a public or private sale, or both,
with or without having the Collateral present at the time of the sale, which sale shall be on
such terms and conditions and conducted in such manner as the Lender determines in its sole
judgment to be

 

 

FORM 6281 (6-2006)

Page 25 of 39

39

commercially reasonable. Any deficiency that exists after the disposition or
liquidation of the Collateral shall be a continuing liability of the Borrower to the Lender
and shall be immediately paid by the Borrower to the Lender.

Section 8.3.7 Non-Exclusivity of Remedies. Exercise one or more of the Lender’s
rights set forth herein or exercise any and all rights or remedies granted to it under any
Loan Document, by applicable law, or otherwise, including the right to accelerate the
maturity of the Loan and to proceed against all or any portion of the Collateral, in any
order. In addition, the Lender may hold and set off and apply against the Loan any and all
accounts or other property in the possession of or under the control of Lender. All rights
and remedies granted to the Lender under the Loan Documents or this Agreement or available
under applicable law shall be deemed concurrent and cumulative and not alternative remedies,
and the Lender may proceed with any number of such remedies at the same time until
obligations of the Borrower to the Lender are paid and satisfied in full. The exercise of
any one right or remedy shall not be deemed a waiver or release of any other right or remedy,
and the Lender, upon the occurrence of any Event of Default, may proceed against the Borrower
at any time, with any available remedy and in any order.

Section 8.3.8 Application of Proceeds. All amounts received by the Lender as
proceeds from the disposition or liquidation of the Collateral shall be applied to the Loan
as follows: first, to the costs and expenses of collection, enforcement, protection and
preservation of the Lender’s lien in the Collateral, including court costs and reasonable
attorney’s fees, whether or not suit is commenced by the Lender; next, to those costs and
expense incurred by the Lender in protecting, preserving, enforcing, collecting, liquidating,
selling or disposing of the Collateral; next, to the payment of accrued and unpaid interest
on all of the Loans; next, to the payment of the outstanding principal balance of the Loan;
and last, to the payment of any other indebtedness owed by the Borrower to the Lender.

ARTICLE 9 — MISCELLANEOUS

Section 9.1 Entire Agreement and Amendments. This Agreement and all documents and
agreements mentioned herein constitute the entire and complete understanding of the parties hereto
and supercede all prior agreements and understandings relative to the subject matter hereof. It
may not be effectively amended, changed, altered or modified, except in writing executed by all
parties. To the extent the provisions contained in this Agreement are inconsistent with those
contained in any other document, instrument or agreement executed pursuant hereto, the terms and
provisions contained herein shall control. Otherwise, such provisions shall be considered
cumulative.

Section 9.2 Survival. All representations, warranties, covenants and agreements herein
contained on the part of Borrower shall survive the termination of this Agreement and shall be
effective until the Loan is repaid and performed in full.

Section 9.3 Severability. Whenever possible, each provision of this Agreement shall be
interpreted in such manner as to be effective and valid under applicable law, but if any provision
of this Agreement shall be prohibited by or invalid under applicable law, such provision shall be
ineffective only to the extent of such prohibition or invalidity, without invalidating the
remainder of any such provision.

Section 9.4 No Waiver; Cumulative Remedies. If Lender shall waive any power, right or
remedy arising hereunder or under any applicable law, such waiver shall not be deemed to be a
waiver upon the later occurrence or recurrence of any of said events. No failure or delay on the
part of Lender in exercising any right, power or remedy under the Loan Documents, or in extending
time for payment, accepting partial payment or release of any Collateral or proceeds of any
Collateral, or failure to enforce strict compliance with any covenant or condition contained
herein, shall operate as a waiver; nor shall any single or partial exercise of any such right,
power or remedy preclude any other or further exercise thereof or the exercise of any other right,
power or remedy under the Loan Documents. The remedies provided in the Loan Documents are
cumulative and not exclusive of any remedies provided by law.

Section 9.5 Costs and Expenses. Borrower shall pay Lender’s out-of-pocket costs and
expense incurred in connection with the making or disbursement of the Loan or in the exercise of
any of its rights or remedies under this Agreement, including, but not limited to, title insurance,
legal fees, appraisal fees, architect or consultant’s fees, Lender inspection fees and any other
reasonable fees and costs for services that are not customarily performed by Lender’s salaried
employees and are not specifically covered by any commitment fee for the Loan. All such costs and
expenses constitute obligations secured by the Collateral. The provisions of this Section shall
survive the termination of this Agreement and the repayment of the Loan.

 

 

FORM 6281 (6-2006)

Page 26 of 39

39

Section 9.6 Notices. All notices, requests and demands to or upon the respective
parties hereto to be effective shall be in writing (including by facsimile transmission) and,
unless otherwise expressly provided herein, shall be deemed to have been duly given or made when
delivered by hand, or three days after being deposited in the mail, postage prepaid, or, in the
case of telecopy notice, when received, or, in the case of delivery by a nationally recognized
overnight courier, when received, addressed to one or more of the individuals executing this
Agreement on behalf of such party at the address appearing below the signature of such party, or to
such other address as such party may designate for itself by like notice.

Section 9.7 Assignments and Participations. The terms of this Agreement shall bind and
benefit the heirs, legal representatives, successors, and assigns of the parties; provided,
however, that the Borrower may not assign this Agreement, or any Advances made hereunder, or assign
or delegate any of its rights or obligations, without the prior written consent of Lender. Lender
shall have the right to sell participations in the Loan to any other entities without the consent
of, or notice to, the Borrower, provided that no such action by Lender shall relieve Lender of its
obligations to make advances under the Loan when required by this Agreement. Lender may disclose
to any participants or prospective participants any information or other data or material in
Lender’s possession relating to the Borrower, and matters pertinent to the Loan, without the
consent of, or notice to, the Borrower.

Section 9.7.1 Patronage. For purposes of Lender’s patronage program, the Loans will
be treated as a patronage transaction and Borrower will be eligible to receive any patronage
under such patronage program on that portion of the Loans retained by Lender. Lender further
agrees that any patronage paid to Lender with respect to any participation interest sold to
others shall be paid to Borrower.

Section 9.8 Advice from Independent Counsel. The parties hereto understand that this
Agreement is a legally binding agreement that may affect such party’s rights. Each party hereto
represents to the other that it has received legal advice from counsel of its choice regarding the
meaning or legal significance of this Agreement and that it is satisfied with its legal counsel and
the advice received.

Section 9.9 Governing Law; Jurisdiction; Waiver of Jury Trial.

Section 9.9.1 Governing Law. The Loan Documents shall be governed by, and construed
in accordance with, the laws of the State of Nebraska, except to the extent that the law of
any other jurisdiction applies as to the perfection or enforcement of the Lender’s security
interest in or lien on any Collateral and except to the extent expressly provided to the
contrary in any Loan Document.

Section 9.9.2 Jurisdiction. Each Lender and Borrower hereby irrevocably submits to
the jurisdiction of any state or federal court sitting in the State of Nebraska, in any
action or proceeding arising out of or relating to this Agreement or any of the other Loan
Documents, and agrees that all claims in respect of such action or proceeding may be heard
and determined in such state or federal court. The Borrower hereby irrevocably waives, to
the fullest extent it may effectively do so, the defense of an inconvenient forum to the
maintenance of such action or proceeding. The Borrower irrevocably consents to the service
of copies of the summons and complaint and any other process which may be served in any such
action or proceeding by the mailing of copies of such process to the Borrower at its address
specified herein. The Borrower agrees that a final judgment in any such action or proceeding
may be enforced in other jurisdictions by suit on the judgment or in any other manner
provided by law. Nothing in this Section shall affect the right of Lender to service legal
process in any other manner permitted by law or affect the right of Lender to bring any
action or proceeding against the Borrower or their property in the courts of other
jurisdictions.

Section 9.9.3 WAIVER OF JURY TRIAL. THE BORROWER AND THE LENDER HEREBY IRREVOCABLY
WAIVE ALL RIGHT TO TRIAL BY JURY IN ANY ACTION, PROCEEDING OR COUNTERCLAIM ARISING OUT OF OR
RELATING TO THIS AGREEMENT OR ANY LOAN DOCUMENT.

Section 9.10 Headings. The headings herein are for convenience only and in no way define,
limit or describe the scope or intent of any provisions or sections of this Agreement.

Section 9.11 Counterparts. This Agreement may be executed in several counterparts and
such counterparts together shall constitute one and the same instrument.

 

 

FORM 6281 (6-2006)

Page 27 of 39

39

Section 9.12 Non-Business Day. If any payment of principal or interest shall fall
due on a day which is not a Business Day, interest at the rate such Loan bears for the period prior
to maturity shall continue to accrue on such principal from the stated due date thereof to and
including the next succeeding Business Day on which the same is payable.

Section 9.13 No Third Party Beneficiaries. This Agreement, the Loan Documents and the
advances and disbursements hereunder and thereunder are for the sole benefit of Lender and
Borrower, and no third parties shall have any rights or benefits hereunder or thereunder, whether
pursuant to any theory of third party beneficiary or otherwise.

Section 9.14 Set Off. Any funds of Borrower held by Lender in any account are subject to
applicable policies and procedures as may be adopted by Lender from time to time. Borrower grants
Lender a security interest in all of said funds and may exercise the right to apply these funds
against any Loan.

Section 9.15 Disbursement Authorization. Any person executing this Agreement on behalf of
the Borrower is authorized to request, accept, receive, and receipt for all or any portion of the
proceeds of the Loans or of any refinance, conversion, extension, additional loan, reamortization
or revision of the same and to execute and approve all agreements required by Lender in the
disbursement of Loan proceeds. Such person, and/or authorized personnel as disclosed on Schedule
9.15, may initiate/request either by phone, in person or in writing disbursements in the form of
check, wire or electronic transfer to the account specified by requestor. Lender is authorized to
disburse or retain any amounts required to: purchase stock in Lender; pay any fees or charges
required to be paid to Lender: pay other services provided by or through Lender; obtain any
evidence of title to Collateral; satisfy any title requirements required to clear title or obtain
Lender’s required lien position on Collateral; and pay any letters of credit issued for or on
behalf of Borrower.

Upon any verbal or written request of Borrower, or their authorized representative, for a wire
transfer (“Payment Order”) Lender shall wire transfer funds through AgriBank, FCB or other
commercial bank chosen by Lender and qualified to execute the transfer, to an account identified in
the verbal or written instructions. Wire instructions are to be sufficiently complete to allow
Lender to execute the Payment Order and will include, at a minimum, the name and number of
beneficiary financial institution, any intermediary financial institutions as applicable, and a
beneficiary name and account number. Every receiving or beneficiary financial institution may rely
on the identifying number to make payment even if it identifies a financial institution, person, or
account other than the one named. Lender will accept the wiring instructions as provided to it and
is under no obligation to verify the authenticity or accuracy of the instructions.

Borrower is liable for all losses relating to unauthorized transactions which do not result solely
from the gross negligence or intentional misconduct by Lender.

All wire transfers will be made in U.S. dollars unless otherwise specified in the wiring
instructions. For wire transfers requested by Borrower in a foreign currency, Borrower agrees to
accept and bear the foreign exchange risk for converted currency. Borrower acknowledges delays in
beneficiary’s receipt of wire transfers to foreign banks and agrees to hold harmless Lender against
such delays.

Borrower agrees to repay all Payment Orders made by wire transfer in accordance with the terms and
conditions of the Credit Agreement and other Loan Documents. Lender will have no obligation to
execute wire transfer payment order at the request of Borrower or an authorized representative of
Borrower if such disbursement would result in any indebtedness of Borrower being in excess of Loan
to Borrower.

Section 9.16 Confidentiality; Sharing Information. Lender shall hold all non-public
information obtained by Lender pursuant to the requirements of this Agreement in accordance with
Lender’s customary procedures for handling confidential information of this nature; provided,
however, Lender may disclose such confidential information (i) to its examiners, affiliates,
outside auditors, counsel and other professional advisors, (ii) to any prospective purchasers under
Section 9.7 herein, (iii) as required under the Regulations of the Farm Credit Administration, (iv)
to any guarantors of the Loan or third parties pledging collateral as security for the Loan, and
(v) to any officers, managers, members, partners, personal representatives, employees, agents or
other persons authorized by Borrower to receive confidential information as set out in the Schedule
of Authorized Persons attached to this Agreement as Schedule 9.16 or as otherwise authorized in
writing by Borrower on a form approved by Lender. Such authorization shall survive the repayment
of the Loan(s) and the termination of this Agreement and can only be revoked by written notice to
Lender.

Section 9.17 Anti-Terrorism Laws. To the best of its knowledge, neither Borrower nor any
of its Affiliates is in violation of (i) any of the foreign assets control regulations of the
United States Treasury Department (31 CFR, Subtitle B, Chapter V, as amended) or any enabling
legislation or executive order relating thereto, (ii) Executive Order No. 13,224, 66 Fed

 

 

FORM 6281 (6-2006)

Page 28 of 39

39

Reg 49,079 (2001), issued by the President of the United States (Executive Order Blocking
Property and Prohibiting Transactions with Persons Who Commit, Threaten to Commit or Support
Terrorism) (the “Executive Order”) or (iii) the anti-money laundering provisions of the
Uniting and Strengthening America by Providing Appropriate Tools Required to Intercept and Obstruct
Terrorism (USA PATRIOT ACT) Act of 2001, Public Law 107-56 (October 26, 2001) amending the Bank
Secrecy Act, 31 U.S.C. Section 5311 et seq (collectively, “Anti-Terrorism Laws”).

Section 9.18 Payer of Record. E Energy Adams, LLC is identified as the primary
customer/payer of record as Borrower under this Agreement to accept and receive tax notices and any
dividend, patronage, or other distributions declared by Lender.

Section 9.19 IRS Declaration. The Internal Revenue Service does not require your consent
to any provision of this document other than the following certification required to avoid backup
withholding. Under penalties of perjury, I/we certify that the Taxpayer Identification Number
shown herein is correct and that I/we am/are not subject to backup withholding either because I/we
are exempt, have not been notified that I/we are subject to backup withholding due to failure of
reporting interest or dividends, or the Internal Revenue Service has notified me/us that I/we
am/are no longer subject to backup withholding. I/we am/are a U.S. person (including U.S. resident
alien):

     E Energy Adams, LLC                    20-2627531

Section 9.20
Principal Headquarters. Borrower’s principal headquarters and the place
where the records required by Section 6.5 are kept is located at 510 Main Street, Adams, NE 68301.

IN WITNESS WHEREOF, the parties hereto have set their hand effective the day and year first above
written.

BORROWER:

	 	 	 	 	 
	E Energy Adams, LLC

 	 	 
	By:  	/s/ Jack L. Alderman
 	 	 
	 	Jack L. Alderman, President 	 	 
	 	 	 
	By:  	                     /s/ Dennis L. Boesiger
 	 	 
	 	Dennis L. Boesiger, Secretary 	 	 

Address for Notice: 510 Main Street, Adams, NE 68301

 

 

FORM 6281 (6-2006)

Page 29 of 39

39

LENDER:

	 	 	 	 	 
	Farm Credit Services of America, FLCA 

Farm Credit Services of America, PCA

 	 	 
	By:  	/s/ Shane Frahm
 	 	 
	 	Shane Frahm, Vice President 	 	 

Address for Notice: 5015 South 118th Street, Omaha, NE 68137

 

 

FORM 6281 (6-2006)

Page 30 of 39

39

Facility

EXHIBIT A

Parcel A: The Southeast Quarter of the Southwest Quarter of Section 17, Township 6 North,
Range 8 East of the 6th P.M., Gage County, Nebraska

Parcel B: East Half of the Northwest Quarter of the Northeast Quarter; Southwest Quarter of the
Northeast Quarter; Northwest Quarter of the Southeast Quarter; Northeast Quarter of the Southwest
Quarter; and the Southeast Quarter of the Northwest Quarter, all in Section 17, Township 6 North,
Range 8 East of the 6th P.M., Gage County, Nebraska, except the railroad right-of-way of record;
and a certain Easement of record executed by M. James Platt, Trustee and individually, and Bernice
R. Platt, Trustee and individually, and Abbie Wood, Trustee and individually, on or about the 1st
day of November 1995, and filed for record in Book 78, Page 769, in the Register of Deeds’ Office,
Gage County, Nebraska on the 16th day of January, 1996 wherein a perpetual easement was granted
over the East 20 feet of the Southwest Quarter of the Southeast Quarter of Section 17, Township 6
North, Range 8 East of the 6th P.M., Gage County, Nebraska, for use as driveway for ingress and
egress in and to the premises.

Tract I: A tract of land located in part of the Northeast Quarter of the Northwest Quarter,
together with a tract of land located in part of the Northwest Quarter of the Northwest Quarter of
Section 17, Township 6 North, Range 8 East of the 6th P.M., Gage County, Nebraska, said tract lying
Westerly of the Burlington Northern Santa Fe Railroad, described as follows: Commencing at the
Southwest Corner of said Northeast Quarter of the Northwest Quarter; thence N88°57’14“E (assumed
bearing) on the South line of said Northeast Quarter of the Northwest Quarter, 255.43 feet to the
point of beginning; thence N40°29’04“W parallel with the Westerly R.O.W. line of the Burlington
Northern Santa Fe Railroad, 1135.00 feet to the center line more or less of the Little Nemaha
River; thence S66°39’28“E on said center line more or less, 152.45 feet; thence S77°24’16“E on said
centerline more or less, 221.00 feet to the Westerly R.O.W. line of the Burlington Northern Santa
Fe Railroad; thence S40°29’04“E on said Westerly R.O.W. line, 986.00 feet to the South line of said
Northeast Quarter of the Northwest Quarter; thence S88°57’14“W on said South line, 258.96 feet to
the point of beginning.

Tract III: A tract of land located in part of the Southwest Quarter of the Southeast Quarter of
Section 17, Township 6 North, Range 8 East of the 6th P.M., Gage County, Nebraska, said tract lying
Westerly of the Burlington Northern Santa Fe Railroad, described as follows: Beginning at the
Northeast corner of said Southwest Quarter of the Southeast Quarter; thence S00°02’44“W (assumed
bearing) on the East line of said Southwest Quarter of the Southeast Quarter; 331.24 feet; thence
Northwesterly on a 3469.72 foot curve to the left (chord bearing N38°47’59“W, chord distance 204.03
feet) to the point of tangency; thence N40°29’04“W parallel with the Westerly R.O.W. line of the
Burlington Northern Santa Fe Railroad, 219.15 feet to the North line of said Southwest Quarter of
the Southeast Quarter; thence N88°49’24“E on said North line, 270.44 feet to the point of
beginning.

Tract IV: A tract of land located in part of the Northeast Quarter of the Southeast Quarter of
Section 17, Township 6 North, Range 8 East of the 6th P.M., Gage County, Nebraska, said tract lying
Westerly of the Burlington Northern Santa Fe Railroad, described as follows: Beginning at the
Southwest corner of said Northeast Quarter of the Southeast Quarter; thence N00°02’44“E (assumed
bearing) on the West line of said Northeast Quarter of the Southeast Quarter, 139.63 feet to the
Westerly R.O.W. line of the Burlington Northern Santa Fe Railroad; thence S40°29’04“E on said
Westerly R.O.W. line, 153.94 feet to the point of curvature; thence Southeasterly on a 3769.72 foot
radius curve to the right (chord bearing S40°17’02“E, chord distance of 26.39 feet) to the South
line of said Northeast Quarter of the Southeast Quarter; thence S88°49’24“W on said South line,
117.16 feet to the point of beginning.

Tract V: A tract of land located in part of the Northeast Quarter of the Northeast Quarter of
Section 20, Township 6 North, Range 8 East of the 6th P.M., Gage County, Nebraska, together with
part of the Southeast Quarter of the Southeast Quarter of Section 17, Township 6 North, Range 8
East of the 6th P.M., Gage County, Nebraska; said tracts lying Westerly of the Burlington Northern
Santa Fe Railroad, described as follows: Beginning at the Southeast corner of said Northeast Quarter of the Northeast
Quarter of said Section 20; thence S88°46’05“W (assumed bearing)
on the South line

 

 

FORM 6281 (6-2006)

Page 31 of 39

39

of said Northeast Quarter of the Northeast Quarter, 202.08 feet; thence
N19°33’28“W parallel with the Westerly R.O.W. line of the Burlington Northern Santa Fe Railroad,
1388.00 feet to the North line of said Northeast Quarter of the Northeast Quarter of said Section
20; thence continuing N19°33’28“W, 78.81 feet to the point of curvature; thence Northwesterly on a
3569.72 foot radius curve to the left (chord bearing N29°22’14“W, chord distance 1216.80 feet) to
the West line of said Southeast Quarter of the Southeast Quarter of said Section 17; thence
N00°02’44“E on said West line, 169.54 feet to the Northwest corner of said Southeast Quarter of the
Southeast Quarter of said Section 17; thence N88°49’24“E on the North line of said Southeast
Quarter of the Southeast Quarter, 117.16 feet to the Westerly R.O.W. line of the Burlington
Northern Santa Fe Railroad; thence Southeasterly on said Westerly R.O.W. line on a 3769.72 foot
radius curve to the right (chord bearing S29°49’14“E, chord distance 1343.26 feet) to the point of
tangency; thence S19°33’28“E on said Westerly R.O.W. line, 145.04 feet to the South line of said
Southeast Quarter of the Southeast Quarter of said Section 17; thence continuing S19°33’28“E on
said Westerly R.O.W. line, 1363.44 feet to the East line of said Northeast Quarter of the Northeast
Quarter of said Section 20; thence S00°54’51“W on said East line, 23.36 feet to the point of
beginning.

Tract VI: A tract of land located in part of the Northeast Quarter of the Northeast Quarter of
Section 20, Township 6 North, Range 8 East of the 6th P.M., Gage County, Nebraska, together with
part of the Southeast Quarter of the Southeast Quarter of Section 17, Township 6 North, Range 8
East of the 6th P.M., Gage County, Nebraska; said tracts lying Westerly of the Burlington Northern
Santa Fe Railroad, described as follows: Beginning at the Southeast corner of said Northeast
Quarter of the Northeast Quarter of said Section 20; thence S88°46’05“W (assumed bearing) on the
South line of said Northeast Quarter of the Northeast Quarter, 202.08 feet to the point of
beginning; thence continuing S88°46’05“W on said South line, 105.34 feet; thence N19°33’28“W
parallel with the Westerly R.O.W. line of the Burlington Northern Santa Fe Railroad, 1388.00 feet
to the North line of said Northeast Quarter of the Northeast Quarter of said Section 20; thence
continuing N19°33’28“W, 45.70 feet to the point of curvature; thence Northwesterly on a 3469.72
foot radius curve to the left (chord bearing N28°20’11“W, chord distance 1059.07 feet) to the West
line of said Southeast Quarter of the Southeast Quarter of said Section 17; thence N00°02’44“E on
said West line, 161.70 feet; thence Southeasterly on a 3569.72 foot radius curve to the right
(chord bearing S29°22’14“E, chord distance 1216.80 feet to the point of tangency; thence
S19°33’28“E parallel with the Westerly R.O.W. line of the Burlington Northern Santa Fe Railroad,
78.81 feet to the South line of said Southeast Quarter of the Southeast Quarter of said Section 17;
thence continuing S19°33’28“E, 1388.00 feet to the point of beginning.

 

 

FORM 6281 (6-2006)

Page 32 of 39

39

Exhibit ‘B’

Promissory Note

	 	 	 
	$.00

	 	Effective Date: ___, 2006

     FOR VALUE RECEIVED, E Energy Adams, LLC (“Maker”), promises to pay to the order of Farm Credit
Services of America, FLCA (“FCSA”) at its office at 5015 South 118th St., Omaha,
Nebraska 68137, or such other place as FCSA shall direct in writing, the principal sum of >
Dollars ($.00) or, if less, the amount outstanding under this Note for Advances pursuant to the
Credit Agreement dated as of ___, 2006, by and between FCSA and Maker (as it may be amended
from time to time in the future, the “Credit Agreement”) and any indebtedness related thereto.
This Note is issued and delivered to FCSA pursuant to the Credit Agreement. All capitalized terms
used in this Note and not otherwise defined herein shall have the same meanings as set forth in the
Credit Agreement.

     The unpaid balance of this Note from time to time outstanding shall bear interest as set forth
in the Credit Agreement. Principal and interest shall be payable as provided in the Credit
Agreement. The amount of each principal and interest payment shall be determined as provided in the
Credit Agreement. This Note has been issued by Maker to FCSA pursuant to the Credit Agreement and
reference is made thereto for specific terms and conditions under which this Note is made and to
which this Note is subject.

     Upon the occurrence of an Event of Default, Maker agrees that FCSA (including its assignee,
“Holder”) shall have all rights and remedies set forth in the Credit Agreement, including without
limitation the rights of acceleration set forth in the Credit Agreement. In addition, Holder shall
have the right to recover all costs of collection and enforcement of this Note as provided in the
Credit Agreement.

     Maker and any endorser, guarantor, surety or assignor hereby waives presentment for payment,
demand, protest, notice of protest, and notice of dishonor and nonpayment of this Note, and all
defenses on the ground of delay, suretyship, impairment of collateral, or of extension of time at
or after maturity for the payment of this Note.

     This Note shall be governed in all respects by the law of the State of Nebraska.

	 	 	 	 	 
	 	Maker:

E Energy Adams, LLC

 	 
	 	By:  	 	 
	 	 	Name:  	 	 
	 	 	Title:  	 	 

 

 

	 	 	 	 	 

FORM 6281 (6-2006)

Page 33 of 39

39

Exhibit ‘C’

Form of Draw Request

Date, 2006

Farm Credit Services of America

5015 South 118th Street

Omaha, Nebraska 68137

Attention: Shane Frahm

Dear Sir:

Reference is made to the Credit Agreement dated as of Date, 2006 (as amended and in effect on the
date hereof, the “Credit Agreement”), between the undersigned, as Borrower, and Farm Credit
Services of America, as Lender. Terms defined in the Credit Agreement are used herein with the same
meanings. This notice constitutes a Draw Request, and Borrower hereby requests a Borrowing under
the Credit Agreement, and in that connection Borrower specifies the following information with
respect to the Borrowing requested hereby:

	(A)	 	Aggregate principal amount of
Borrowing1:                                             
	 
	(B)	 	Date of Borrowing (which is a Business Day):                                         

Borrower hereby represents and warrants that the conditions specified in Subsections 3.2 to 3.4,
inclusive, of the Credit Agreement are satisfied and requests that payment be made in accordance
with the Disbursement Order attached hereto.

	 	 	 	 	 
	 	Very truly yours,

E Energy Adams, LLC

 	 
	 	By:  	 	 
	 	 	Name:  	 	 
	 	 	Title:  	 	 
	 

 

			
	1	 	Not less than $100,000 and an integral multiple of $100,000.

 

 

FORM 6281 (6-2006)

Page 34 of 39

39

Exhibit ‘D’

 

 

FORM 6281 (6-2006)

Page 35 of 39

39

Schedule 7.9

Loans, Advances and Guarantees

None

 

 

FORM 6281 (6-2006)

Page 36 of 39

39

Schedule 7.14

Deposit and Investment Accounts

Adams State Bank

 

 

FORM 6281 (6-2006)

Page 37 of 39

39

Schedule 7.15

Investments

None

 

 

FORM 6281 (6-2006)

Page 38 of 39

39

Schedule 9.15

Customer Disbursement Authorization for Non-Signers on Note

Customer Name: E Energy Adams, LLC

	 	 	 	 	 	 	 
	CTL3: 268

	 	CIF:
	 	Note(s):
	 	Draw(s):

I hereby authorize Farm Credit Services of America, PCA/FLCA (“Lender”) to execute request(s) to
advance funds from above stated loan(s) by wire transfer and/or check, based on instructions
provided by phone, in person, or in writing by a party authorized by me as stated below in this
agreement.

	 	 	 	 
	Name of Authorized Individual(s)

	 	Signature of Authorized Individual(s)
	 
	 	 
	 

	 	 
	 
	 	 
	 

	 	 
	 
	 	 
	 

	 	 
	 
	 	 
	 

	 	 

I agree that my access to wire transfer and check disbursement services pursuant to this agreement
are also subject to all of the terms and conditions contained in the Credit Agreement and related
documents evidencing my borrowing relationship with Lender.

I further understand that any disbursement request is subject to approval by Lender and that Lender
may refuse to execute and complete a request if such request causes the loan to exceed the
available commitment.

Authorization granted by (at least one primary obligor):

	 	 	 	 
	 

	 	 
	 
	 	 
	 

	 	 
	 
	 	 
	 

	 	 
	 
	 	 
	 

	 	 

Date:
                                   

 

 

FORM 6281 (6-2006)

Page 39 of 39

39

Schedule 9.16

Schedule of Authorized Persons

Pursuant to Section 9.16 Confidentiality; Sharing Information of the Credit Agreement
between E Energy Adams, LLC and Farm Credit Services of America, FLCA and Farm Credit Services of
America, PCA dated August 11, 2006, Lender may disclose such confidential information (i) to its
examiners, affiliates, outside auditors, counsel and other professional advisors, (ii) to any
prospective purchasers under Section 9.7 herein, (iii) as required under the Regulations of the
Farm Credit Administration, (iv) to any guarantors of the Loan or third parties pledging collateral
as security for the Loan, and (v) to any officers, managers, members, partners, personal
representatives, employees, agents or other persons authorized by Borrower to receive confidential
information as set out in the Schedule of Authorized Persons

I/We hereby release and agree to hold Lender, its directors, officers, employees, and agents
harmless from any liability whatsoever which might arise at any time by reason of any release,
disclosure, or publication of said information to the person(s) identified herein.

PERSON(S) AUTHORIZED TO RECEIVE INFORMATION:

(If none, please write “none”)

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00115-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00115-of-00352.parquet"}]]