Document:

Exhibit 4.19

 

Shipbuilding and Construction Agreements
between  Stolt-Nielsen Transportation
Group B.V. and ShinA Shipbuilding Co., Ltd.

 

	
  Signing Date

  	
   

  	
  Hull No.

  	
   

  	
  Delivery Date

  	
   

  
	
  June 9, 2005

  	
   

  	
  S-473

  	
   

  	
  May 28, 2008

  	
   

  
	
  June 9, 2005

  	
   

  	
  S-474

  	
   

  	
  September 30, 2008

  	
   

  
	
  June 9, 2005

  	
   

  	
  S-475

  	
   

  	
  November 27 2008

  	
   

  
	
  June 9, 2005

  	
   

  	
  S-476

  	
   

  	
  February 12, 2009

  	
   

  

 

On June 9, 2005,
Stolt–Nielsen S.A.’s wholly owned subsidiary Stolt-Nielsen Transportation Group
B.V., entered into four separate agreements with ShinA Ship Building Co. Ltd.
for the construction and sale of four parcel tankers. Other than the delivery
dates, designated in the table above, there are no material differences between
the agreements.  The agreement for the sale
of parcel tanker Hull No. S-473 is attached hereto as a form.

 

 

SHIPBUILDING CONTRACT

 

FOR

 

THE CONSTRUCTION AND SALE

 

OF

 

One (1) DWT 44,000 IMO II/III
Product/Chemical Tanker

(HULL NO. S473)

 

BY AND BETWEEN

 

STOLT-NIELSEN TRANSPORTATION
GROUP B.V.

As Buyer

 

AND

 

SHINA SHIPBUILDING CO., LTD.

As Builder

 

 

INDEX

 

	
  PREAMBLE

  	
  P-1

  
	
   

  	
   

  
	
  ARTICLE I - DESCRIPTION AND CLASS

  	
  I-l

  
	
   

  	
   

  
	
  1. Description:

  	
  I-1

  
	
   

  	
   

  
	
  2. Dimensions and Characteristics:

  	
  I-1

  
	
   

  	
   

  
	
  3. Classification, Rules and Regulations:

  	
  I-2

  
	
   

  	
   

  
	
  4. Subcontracting:

  	
  I-3

  
	
   

  	
   

  
	
  5. Registration:

  	
  I-3

  
	
   

  	
   

  
	
  ARTICLE II - CONTRACT PRICE AND TERMS OF PAYMENT 

  	
  II-l

  
	
   

  	
   

  
	
  1.    Contract Price:

  	
  II-1

  
	
   

  	
   

  
	
  2. Adjustment of Contract Price:

  	
  II-1

  
	
   

  	
   

  
	
  3. Currency:

  	
  II-1

  
	
   

  	
   

  
	
  4. Terms of Payment:

  	
  II-1

  
	
   

  	
   

  
	
  5. Method of Payment:

  	
  II-3

  
	
   

  	
   

  
	
  6. Notice of Payment on or before Delivery:

  	
  II-4

  
	
   

  	
   

  
	
  7. Expenses:

  	
  II-4

  
	
   

  	
   

  
	
  8. Prepayment:

  	
  II-4

  
	
   

  	
   

  
	
  9. Documentation:

  	
  II-5

  
	
   

  	
   

  
	
  ARTICLE III - ADJUSTMENT OF CONTRACT PRICE 

  	
  III-1

  
	
   

  	
   

  
	
  1. Delivery:

  	
  III-1

  
	
   

  	
   

  
	
  2. Speed:

  	
  III-3

  
	
   

  	
   

  
	
  3. Fuel Consumption:

  	
  III-3

  
	
   

  	
   

  
	
  4. Deadweight:

  	
  III-4

  
	
   

  	
   

  
	
  5. Steel Weight Adjustment

  	
  III-4

  
	
   

  	
   

  
	
  6. Steel Price Adjustment

  	
  III-5

  
	
   

  	
   

  
	
  7. Effect of Cancellation:

  	
  III-6

  
	
   

  	
   

  
	
  ARTICLE IV - APPROVAL OF PLANS AND DRAWINGS AND
  INSPECTION

  	
   

  
	
  DURING CONSTRUCTION

  	
  IV-1

  
	
   

  	
   

  	
   

  
	
  1. Approval of Plans and Drawings:

  	
  IV-1

  
	
   

  	
   

  
	
  2. Appointment of BUYER’s Supervisor:

  	
  IV-2

  
	
   

  	
   

  
	
  3. Inspection by the Supervisor:

  	
  IV-2

  
	
   

  	
   

  
	
  4. Facilities:

  	
  IV-4

  
	
   

  	
   

  
	
  5. Liability of BUILDER:

  	
  IV-4

  
	
   

  	
   

  
			

 

 

	
  6. Responsibility of BUYER:

  	
  IV-4

  
	
   

  	
   

  
	
  ARTICLE V - MODIFICATIONS, CHANGES AND EXTRAS

  	
  V-1

  
	
   

  	
   

  
	
  1. Modification of Specifications:

  	
  V-1

  
	
   

  	
   

  
	
  2. Changes in Rules of Classification
  Society, Regulations, etc.:

  	
  V-2

  
	
   

  	
   

  
	
  3. Substitution of Materials:

  	
  V-3

  
	
   

  	
   

  
	
  ARTICLE VI - TRIALS AND ACCEPTANCE

  	
  VI-1

  
	
   

  	
   

  
	
  1. Notice:

  	
  VI-1

  
	
   

  	
   

  
	
  2. Weather Condition:

  	
  VI-1

  
	
   

  	
   

  
	
  3. How Conducted:

  	
  VI-2

  
	
   

  	
   

  
	
  4. Method of Acceptance or Rejection:

  	
  VI-2

  
	
   

  	
   

  
	
  5. Effect of Acceptance:

  	
  VI-3

  
	
   

  	
   

  
	
  6. Disposition of Surplus Consumable Stores

  	
  VI-4

  
	
   

  	
   

  
	
  ARTICLE VII - DELIVERY

  	
  VII-1

  
	
   

  	
   

  
	
  1. Time and Place:

  	
  VII-1

  
	
   

  	
   

  
	
  2. When and How Effected:

  	
  VII-1

  
	
   

  	
   

  
	
  3. Documents to be delivered to BUYER:

  	
  VII-1

  
	
   

  	
   

  
	
  4. Tender of VESSEL:

  	
  VII-3

  
	
   

  	
   

  
	
  5. Title and Risk:

  	
  VII-3

  
	
   

  	
   

  
	
  6. Removal of VESSEL:

  	
  VII-3

  
	
   

  	
   

  
	
  ARTICLE VIII - DELAYS AND EXTENSION OF TIME FOR
  DELIVERY

  	
   

  
	
  (FORCE MAJEURE)

  	
  VIII-1

  
	
   

  	
   

  
	
  1. Causes of Delay (Force Majeure):

  	
  VIII-1

  
	
   

  	
   

  
	
  2. Notice of Delay:

  	
  VIII-2

  
	
   

  	
   

  
	
  3. Definition of Permissible Delay:

  	
  VIII-2

  
	
   

  	
   

  
	
  4. Right to Cancel for Excessive Delay: 

  	
  VIII-2

  
	
   

  	
   

  
	
  ARTICLE IX - WARRANTY OF QUALITY

  	
  IX-1

  
	
   

  	
   

  
	
  1. Guarantee:

  	
  IX-1

  
	
   

  	
   

  
	
  2. Notice of Defects:

  	
  IX-2

  
	
   

  	
   

  
	
  3. Remedy of Defects:

  	
  IX-2

  
	
   

  	
   

  
	
  4. Extent of BUILDER’s Responsibility:

  	
  IX-4

  
	
   

  	
   

  
	
  5. Guarantee Engineer:

  	
  IX-5

  

 

 

	
  ARTICLE X - CANCELLATION BY BUYER

  	
  X-l

  
	
   

  	
   

  
	
  1. BUILDER’s Default and Effect of Default

  	
  X-l

  
	
   

  	
   

  
	
  2. Notice:

  	
  .X-2

  
	
   

  	
   

  
	
  3. Refund by BUILDER:

  	
  X-2

  
	
   

  	
   

  
	
  4. Discharge of Obligations:

  	
  X-3

  
	
   

  	
   

  
	
  ARTICLE XI - BUYER’s DEFAULT

  	
  XI-1

  
	
   

  	
   

  
	
  1. Definition of BUYER’s Default:

  	
  XI-1

  
	
   

  	
   

  
	
  2. Effect of Default on or before Delivery of
  VESSEL:

  	
  XI-1

  
	
   

  	
   

  
	
  3. Disposal of VESSEL by BUILDER upon BUYER’s
  Default:

  	
  XI-2

  
	
   

  	
   

  
	
  ARTICLE XII - ARBITRATION

  	
  XII-1

  
	
   

  	
   

  
	
  1. Decision by the Classification Society:

  	
  XII-1

  
	
   

  	
   

  
	
  2. Proceedings of Arbitration:

  	
  XII-1

  
	
   

  	
   

  
	
  3. Work to Continue during Arbitration:

  	
  XII-2

  
	
   

  	
   

  
	
  4. Expenses:

  	
  XII-2

  
	
   

  	
   

  
	
  5. Entry in Court:

  	
  XII-2

  
	
   

  	
   

  
	
  6. Alteration of Delivery Date:

  	
  XII-2

  
	
   

  	
   

  
	
  ARTICLE XIII - SUCCESSOR AND ASSIGNS

  	
  XIII-1

  
	
   

  	
   

  
	
  ARTICLE XIV - TAXES AND DUTIES

  	
  XIV-1

  
	
   

  	
   

  
	
  1. Taxes and Duties Incurred in Korea:

  	
  XIV-1

  
	
   

  	
   

  
	
  2. Taxes and Duties Incurred outside Korea:

  	
  XIV-1

  
	
   

  	
   

  
	
  ARTICLE XV - PATENTS, TRADEMARKS, COPYRIGHTS, ETC

  	
  XV-1

  
	
   

  	
   

  
	
  1. Patents, Trademarks and Copyrights:

  	
  XV-1

  
	
   

  	
   

  
	
  2. General Plans, Specifications and Working
  Drawings:

  	
  XV-1

  
	
   

  	
   

  
	
  ARTICLE XVI -BUYER’s SUPPLIES

  	
  XVI-1

  
	
   

  	
   

  
	
  1. Responsibility of BUYER:

  	
  XVI-1

  
	
   

  	
   

  
	
  2. Responsibility of BUILDER:

  	
  XVI-2

  
	
   

  	
   

  
	
  ARTICLE XVII - INSURANCE

  	
  XVII-1

  
	
   

  	
   

  
	
  1. Extent of Insurance Coverage

  	
  XVII-1

  
	
   

  	
   

  
	
  2. Application of the Recovered Amounts

  	
  XVII-1

  
	
   

  	
   

  
	
  3. Termination of BUILDER’s Obligation to Insure

  	
  XVII-2

  

 

 

	
  ARTICLE XVIII - NOTICE

  	
  XVIII-1

  
	
   

  	
   

  
	
  1. Address:

  	
  XVIII-1

  
	
   

  	
   

  
	
  2. Language:

  	
  XVIII-1

  
	
   

  	
   

  
	
  3. Effective Date of Notice:

  	
  XVIII-2

  
	
   

  	
   

  
	
  ARTICLE XIX - EFFECTIVE DATE OF CONTRACT

  	
  XIX-1

  
	
   

  	
   

  
	
  ARTICLE XX - INTERPRETATION

  	
  XX-1

  
	
   

  	
   

  
	
  1. Laws Applicable:

  	
  XX-1

  
	
   

  	
   

  
	
  2. Discrepancies:

  	
  XX-1

  
	
   

  	
   

  
	
  3. Entire Agreement:

  	
  XX-1

  
	
   

  	
   

  
	
  4. Amendments and Supplements:

  	
  XX-1

  
	
   

  	
   

  
	
  EXHIBIT “A”

  	
  A-l

  
	
   

  	
   

  
	
  EXHIBIT “B”

  	
  B-l

  

 

 

THIS
CONTRACT, made and entered into on this 9th day of June, 2005 by and
between STOLT-NIELSEN TRANSPORTATION GROUP B.V., a corporation incorporated and
existing under the laws of The Netherlands and having its registered office at
Westerlaan 5, 3016 CK Rotterdam, The Netherlands (hereinafter called the “BUYER”),
on the one part and ShinA Shipbuilding Co., Ltd, a corporation
incorporated and existing under the laws of the Republic of Korea and having
its registered office at 227,

Donam-dong, Tongyeong, Gyeongnam, Korea (hereinafter called the “BUILDER”), on
the other part,

 

WITNESSETH:

 

In
consideration of the mutual covenants herein contained, the BUILDER agrees to
design, build, launch, equip, test and complete one(l) Single Screw Diesel
Engine Driven 44,000 DWT Chemical Tanker as described in the Specifications
attached herewith (hereinafter called the “VESSEL”) at the BUILDER’s Shipyard
located in Tongyeong, Korea (hereinafter called the “Shipyard”) and to deliver
and sell the same to the BUYER, and the BUYER hereby agrees to purchase and
take delivery of the VESSEL from the BUILDER and to pay for the same upon the
terms and conditions hereinafter set forth.

 

(End of Preamble)

 

P-1

 

ARTICLE I - DESCRIPTION AND CLASS

 

1.                                       Description:

 

The VESSEL shall be a Single Screw Diesel Engine Driven 44,000 DWT
Chemical Tanker having the BUILDER’s Hull No. S473 and shall be designed,
constructed, equipped, tested and completed in accordance with the provisions
of this Contract, and the specifications (FS-CC43-STOLT-R0) including Maker’s
List and the General Arrangement Plan (O11-B01 dated 27th May 2005)
(hereinafter collectively called the “Specifications”) signed by each of the
parties hereto for identification and attached hereto and made an integral part hereof.

 

2.                                       Dimensions and Characteristics:

 

	
  Length,
  overall

  	
   

  	
  appx.

  	
   

  	
  182.880

  	
   

  	
  M

  
	
  Length, between
  perpendiculars

  	
   

  	
  appx.

  	
   

  	
  175.600

  	
   

  	
  M

  
	
  Breadth, moulded

  	
   

  	
  appx.

  	
   

  	
  32.200

  	
   

  	
  M

  
	
  Depth, moulded

  	
   

  	
  appx.

  	
   

  	
  16.050

  	
   

  	
  M

  
	
  Designed loaded
  draught, moulded

  	
   

  	
  appx.

  	
   

  	
  12.070

  	
   

  	
  M

  
	
  Scantling draught,
  moulded,

  	
   

  	
  appx.

  	
   

  	
  12.070

  	
   

  	
  M

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  Main
  Engine:

  	
   

  	
  B&W
  5S60MC-C, License made MCR 11300 kw at 105 r.p.m.

  
	
   

  	
   

  	
   

  
	
  Deadweight,
  guaranteed:

  	
   

  	
  44,000
  metric tons at the moulded scantling draught of 12.07 meters.

  
	
   

  	
   

  	
   

  
	
  Speed,
  guaranteed:

  	
   

  	
  15.0
  Knots at a draught of 12.07 Meters and main engine developing power of 8843
  kw

  
	
   

  	
   

  	
   

  
	
  Fuel
  Consumption, guaranteed:

  	
   

  	
  170
  grams/kw -hour using marine diesel oil having lower calorific value of 10,200
  Kcal/Kg at maximum continuous rating of main engine measured at the shop
  trial.

  

 

I-1

 

The details of the aforementioned particulars as well as the
definitions and method of measurements and calculations are as defined in the
Specifications.

 

3.                                       Classification, Rules and Regulations:

 

The VESSEL, including its machinery, equipment and outfitting shall be
designed and constructed in accordance with the rules and regulations (the
edition and amendments thereto being in force as of the date of this Contract)
of and under special survey of DET NORSKE VERITAS (hereinafter called the “Classification
Society”) and shall be distinguished in the register by the symbol of +A1,
Tanker for Oil Products, Tanker for Chemicals ESP, NAUT-OC, E0, ETC, VCS-2,
TMON, INERT, Shiptype2, a2, b3, c3, r3, f2, str 0.1, k, D=1.25 (1.50 slack)

 

Or Lloyd’s Register of Shipping with the equivalent notations with
above DET NORSKE VERITAS.

 

Decisions of the Classification Society as to compliance or
non-compliance with the classification shall be final and binding upon both
parties hereto. Details of its notation shall be in accordance with the
Specifications.

 

The VESSEL shall also comply with the rules, regulations and
requirements of the regulatory bodies as described in the Specifications in
effect as of the signing date of this Contract.

 

All the fees and charges incidental to the classification and with
respect to compliance with the above referred rules, regulations and
requirements shall be for account of the BUILDER except otherwise agreed.

 

The BUILDER shall forward to the BUYER copies of all correspondence
exchanged between the BUILDER and the Classification Society and/or the
Regulatory Bodies, if any.

 

I-2

 

4.                                       Subcontracting:

 

The BUILDER may not subcontract a substantial portion of the
construction work of the VESSEL outside the Shipyard but may subcontract a
lesser portion thereof outside the Shipyard to the reputable sub-contractors
within the Korea in the region of Tongyeong, Busan, Ulsan and Geoje Island. The
BUILDER is permitted to sub-contract a portion of the construction work within
the Shipyard without BUYER’s consent. Notwithstanding any such sub-contracting
the BUILDER remain responsible for compliance with the obligations of the
Contract.

 

5.                                       Registration:

 

The VESSEL, at the time of its delivery and acceptance, shall be
registered at the port of registry by the BUYER under the Cayman Islands flag
at the BUYER’s expenses or such other port of Registry as the Buyer may elect
no later than Nine(9) months prior to the estimated delivery date. However
extra cost, in the event of change, shall be for the BUYER’s account.

 

(End of Article)

 

I-3

 

ARTICLE II - CONTRACT PRICE AND TERMS OF
PAYMENT

 

1.                                       Contract Price:

 

The Contract price of the VESSEL, net receivable by the BUILDER and
exclusive of the BUYER’s Supplies as provided in Paragraph 1 of Article XVI
hereof is Fifty Seven Million Four Hundred Eighty Thousand United States
Dollars (US$ 57,480,000) (hereinafter called the “Contract Price”), which shall
be subject to upward or downward adjustment, if any, as hereinafter set forth
in this Contract.

 

2.                                       Adjustment of Contract Price:

 

Increase or decrease of the Contract Price, if any, due to adjustments
thereof made in accordance with the provisions of this Contract, shall be
adjusted by way of addition to or subtraction from the Contract Price upon
delivery of the VESSEL in the manner as hereinafter provided.

 

3.                                       Currency:

 

Any and all payments
by the BUYER to the BUILDER which are due under this Contract shall be made in
United States Dollars.

 

4.                                       Terms of Payment:

 

The Contract Price
shall be due and payable by the BUYER to the BUILDER in the installments as
follows:

 

(For the purpose
of this Contract, the “business day” shall be a banking day in New York and
London and the “telefax” shall be the means of facsimile or internet
transmission)

 

II-1

 

(a)                                  First Installment:

 

The First Installment amounting to Five Million Seven Hundred Forty
Eight Thousand United States Dollars (US$ 5,748,000) shall be due and payable
upon receipt of the original tested telex or SWIFT by the BUYER’s Bank of the
signed Refund Guarantee provided pursuant to Article X but not earlier
than Seventy (70) days after signing this Contract.

 

(b)                                 Second Installment:

 

The Second Installment amounting to Eleven Millions Four Hundred Ninety
Six Thousand United States Dollars (US$ 11,496,000) shall be due and payable on
the date after Fourteen (14) calendar months and Eight (8) days after
signing this Contract.

 

(c)                                  Third Installment:

 

The Third Installment amounting to Five Millions Seven Hundred Forty
Eight Thousand United States Dollars (US$ 5,748,000) shall be due and payable
on the date which the BUYER receives a telefax notice from the BUILDER,
endorsed by the Classification Society, confirming commencement of steel
cutting of the VESSEL.

 

(d)                                 Fourth Installment:

 

The Fourth Installment amounting to Thirty Four Millions Four Hundred
Eighty Eight Thousand United States Dollars (US$ 34,488,000), plus any increase
or minus any decrease due to adjustments of the Contract Price under and
pursuant to the provisions of this Contract, shall be due and payable upon
delivery of the VESSEL or upon tender for delivery of the VESSEL referred to in
Paragraph 4 of Article VII of this Contract.

 

II-2

 

5.                                       Method of Payment:

 

(a)                                  Installments Payable before Delivery:

 

The BUYER shall, at its own cost and expense, remit each of the
respective installments payable before delivery of the VESSEL as provided in
Paragraph 4 of this Article by telegraphic transfer to the account
(Account No. 04-029-695) of the Export-Import Bank of Korea, Seoul, Korea,
with Deutsche Bank Trust Company Americas, N.Y., Church Street Station, New
York, NY10015 or with other bank which the BUILDER may designate in favour
of ShinA Shipbuilding Co., Ltd. (hereinafter called the “BUILDER’s Bank”).

 

(b)                                 Installment Payable on Delivery:

 

At least Three (3) business days prior to the anticipated delivery
date of the VESSEL, the BUYER shall deposit by telegraphic transfer the Fourth
Installment to the account of the BUILDER’s Bank in favour of ShinA
Shipbuilding Co., Ltd. with an irrevocable instruction that the amount so
remitted shall be payable to the BUILDER against a copy of PROTOCOL OF DELIVERY
and ACCEPTANCE OF THE VESSEL signed by the BUYER and the BUILDER.

 

If any interest earned on the account, it shall be paid by the BUILDER’S
to the BUYER.

 

If the BUILDER has not presented the said copy of the PROTOCOL OF
DELIVERY AND ACCEPTANCE to the BUILDER’s bank within Fifteen (15) business days
of the anticipated delivery date, the BUYER may withdraw the deposit
together with all interest earned thereon. If and when the BUILDER advises the
BUYER of a revised scheduled delivery date, the BUYER shall redeposit the
Fourth Installment in the same manner as stated above at least three (3) business
days prior to such scheduled delivery date.

 

II-3

 

Simultaneously with each of all such payments, the BUYER shall cause
the BUYER’s Bank to advise the BUILDER’s Bank of the details of such payments
by authenticated bank cable or telex.

 

No payment under this Contract shall be delayed, suspended or withheld
by the BUYER on account of any dispute or disagreement between the parties
hereto

 

Any claim which the BUYER may have against the BUILDER hereunder
shall be settled and liquidated separately from any payment by the BUYER to the
BUILDER hereunder.

 

6.                                       Notice of Payment on or before Delivery:

 

The BUILDER shall give the BUYER Five (5) business days prior
notice by telefax of the anticipated due date and amount of each installment
payable on or before delivery of the VESSEL.

 

7.                                       Expenses:

 

Expenses and bank charges for remitting payments and any taxes, duties,
expenses and fees connected with such payment shall be for account of the BUYER
referred to in Paragraph 2 of Article XIV of this Contract.

 

8.                                       Prepayment:

 

Prepayment of any installment due on or before delivery of the VESSEL
shall be subject to mutual agreement between the parties hereto.

 

II-4

 

9.                                       Documentation:

 

The BUYER warrants providing the BUILDER within Twenty (20) Business
Days from the signing of the Contract with the following documentation:

 

Certification of incorporation with registered address;

 

Articles of incorporation;

 

Resolution of Directors;

 

List of members of Board of Directors.

 

(End of Article)

 

II-5

 

ARTICLE III - ADJUSTMENT OF CONTRACT
PRICE

 

The Contract Price shall be subject to adjustment, as hereinafter set
forth, in the event of the following contingencies (it being understood by both
parties that any reduction of the Contract Price is by way of liquidated
damages and not by way of penalty):

 

The liquidated damages hereunder shall be the conclusive pecuniary
compensation recoverable in connection with each particular event stated herein
and the BUILDER shall not be liable for any additional compensation claimed by
the BUYER in relation to such particular event and the consequences thereof.

 

1.                                       Delivery:

 

(a)                                  No adjustment shall be made and the Contract
Price shall remain unchanged for the first Thirty (30) days of delay in
delivery of the VESSEL beyond the Delivery Date as defined in Article VII
hereof (ending as of twelve o’clock midnight Korean time of the Thirtieth
(30th) day of delay).

 

(b)                                 If the delivery of the VESSEL is delayed more
than Thirty (30) days after the Delivery Date, the Contract Price shall be
reduced by the sum of Ten Thousand United States Dollars (US$10,000) for each
full day for which thereafter delivery is delayed.

 

However, the total reduction in the Contract Price shall not be more
than as would be the case for a delay of One Hundred and Eighty (180) days
counting from the midnight of the Thirtieth (30th) day after the Delivery Date
at the above specified rate of reduction.

 

(c)                                  However, if the delay in delivery of the
VESSEL should continue for a period of Two Hundred and Ten (210) days from the
Delivery Date in Paragraph 1 of Article VII, then in such event, and after
such period has expired, the BUYER may, at its option, cancel this Contract in
accordance with the provisions of Article X hereof, or may, at its
absolute discretion, accept the

 

III-1

 

VESSEL with a total reduction in the Contract Price for delay of One
Million Eight Hundred Thousand United States Dollars (US$1,800,000).

 

The BUILDER may, at any time after the expiration of the
afore-mentioned Two Hundred and Ten (210) days of delay in delivery, if the
BUYER has not served notice of cancellation as provided in Article X
hereof, demand in writing that the BUYER shall make an election in which case
the BUYER shall, within Twenty(20) days after such demand is received by the
BUYER, notify the BUILDER of its intention either to cancel this Contract or to
consent to the acceptance of the VESSEL at an agreed future date.

 

If the BUYER shall not make an election within Twenty(20) days as
provided hereinabove, the BUYER shall be deemed to have accepted such extension
of the delivery date to the future delivery date indicated by the BUILDER and
it being understood by the parties hereto that if the VESSEL is not delivered
by such future date, the BUYER shall have the same right of cancellation upon
the same terms and conditions as hereinabove provided.

 

(d)                                 If the BUYER formally requests by a letter an
earlier delivery date, in such case, if the delivery of the VESSEL is made more
than Thirty(30) days earlier than the Delivery Date, then, in such event,
beginning with Thirty first (31st) day prior to the Delivery Date,
the Contract Price of the VESSEL shall be increased by adding thereto Ten
Thousand United States Dollars (US$10,000) for each full day. (it being
understood that the BUILDER’s acceptance of such request from the BUYER shall
be in no way construed as change of the Delivery Date under this Contract)

 

(e)                                  For the purpose of this Article, the delivery
of the VESSEL shall be deemed to be delayed when and if the VESSEL, after
taking into account all postponements of the Delivery Date by reason of
permissible delay as defined in Article VIII and /or by any other reason
under this Contract, is not delivered by the date upon which delivery is
required under the terms of this Contract.

 

III-2

 

2.                                       Speed:

 

(a)                                  The Contract Price shall not be affected or
changed by reason of the trial speed, as determined according to the
Specifications, being less than the guarantee speed, if such deficiency is not
more than Three-Tenths(3/10) of One(l) knot.

 

(b)                                 However, if such deficiency is more than
Three-Tenths(3/10) of One(l) knot then, the Contract Price shall be decreased
by One Hundred Ten Thousand United States Dollars (US$110,000) for each
successive whole One Tenth (1/10) of a knot in excess of a deficiency of Three
Tenths (3/10) of a knot speed (smaller fractions being disregarded).

 

If the deficiency in the speed sea trial is more than One(l) full knot
below the guaranteed speed of the VESSEL, then the BUYER may, at its option,
reject the VESSEL and cancel this Contract in accordance with the provisions of
Article X hereof, or may accept the VESSEL at a reduction in the
Contract Price as above provided for One(l) knot only, that is, at a total
reduction of Seven Hundred Seventy Thousand United States Dollars (US$770,000).

 

3.                                       Fuel Consumption:

 

(a)                                  The Contract Price shall not be affected or
changed in case the fuel consumption, as determined by the shop trial as
specified in the Specifications, is not more than Five percent (5%) in excess
of the guaranteed fuel consumption specified in Paragraph 2 of Article I.

 

(b)                                 However, in the event that the actual fuel
consumption at the shop trial is in excess of Five percent (5%) of the
guaranteed fuel consumption, the Contract Price shall be either be reduced by
the sum of Thirty Five Thousand United States Dollars (US$35,000) for each full
gram per kw per hour in excess of the Five percent(5%) (but disregarding
fractions of One(l) gram) of the guaranteed fuel consumption.

 

III-3

 

(c)                                  If such actual fuel consumption exceeds Eight
percent (8%) of the guaranteed fuel consumption of the VESSEL, the BUYER may,
at its option, reject the VESSEL and cancel this Contract in accordance with
the provisions of Article X hereof, or may accept the VESSEL at a
reduction in the Contract Price for excessive fuel consumption as above
specified Eight percent (8%) only, that is, at a total reduction of One Hundred
Seventy Five Thousand United States Dollars (US$175,000).

 

4.                                       Deadweight:

 

(a)                                  In the event that the deadweight of the
VESSEL as determined in accordance with the Specifications is less than the
guaranteed deadweight as specified in Paragraph 2 of Article I, the
Contract Price shall be reduced by the sum of One Thousand Five Hundred United
States Dollars (US$1500) for each full metric ton of such deficiency being more
than Five Hundred (500) metric tons (disregarding the fractions of One(l)
metric ton).

 

(b)                                 In the event of such deficiency in the
deadweight of the VESSEL being One Thousand Two Hundred (1200) metric tons or
more, then, the BUYER may, at its option, reject the VESSEL and cancel this
Contract in accordance with the provisions of Article X hereof or accept
the VESSEL at a reduction in the Contract Price for insufficient deadweight as
above provided for One Thousand Two Hundred (1200) metric tons only, that is,
at a total reduction of One Million Fifty Thousand United States Dollars
(US$1,050,000).

 

5.                                       Steel Weight Adjustment

 

The Contract Price has been calculated on the basis of a net steel
weight of maximum Eight Thousand Seven Hundred Five (8705) metric tons of the
hull (excluding accommodation, the funnel, mid deck stores and outfittings) and
shall be adjusted by adding to the Contract Price the sum of One Thousand Three
Hundred States Dollars (US$ 1300) for each full metric tonne of additional
steel in the net steel weight of the hull of the VESSEL calculated on the basis
of steel drawings as approved by the Classification Society and the BUYER.

 

III-4

 

6.                                       Steel Price Adjustment

 

The Contract Price shall be adjusted by adding to or subtracting from
(as the case may be) the Contract Price the BUYER’s share of the Steel
Price Adjustment Amount excluding the Steel Price Allowance (as defined below)

 

For this purpose, the following definition shall apply:

 

(a)                                  “Steel Price Adjustment Amount” means the
amount of the Steel Adjustment Factor (as defined below) multiplied by Thirteen
percent (13%) of the Contract Price of the Vessel;

 

(b)                                 “Steel Adjustment Factor” means the quotient
of the average (“Md”) of MEPS Asian Carbon Steel Hot Rolled Plate Index
published by MEPS (International) Ltd. of the United Kingdom for the three (3) calendar
months prior to the month in which the Steel Price Reference Date (as defined
below) falls, divided by [“Mc”], minus one (1), i.e. [Md / Mc) – 1; (Mc means
three months average of MEPS Asian Carbon Steel Hot Rolled Plate Index as at
the date of signing this Contract.)

 

(c)                                  “Steel Price Reference Date” means the date
of Keel laying of the Vessel.

 

There shall be no such adjustment of the Contract Price if the Steel
Price Adjustment Amount (as determined pursuant to the provisions set out
above) does not exceed Six Hundred Fifty Thousand United States Dollars
(US$650,000) (the “Steel Price Allowance”), whether such Steel Price Adjustment
Amount is a negative sum or a positive sum.

 

The BUYER’s share shall be Fifty per cent (50%) of the amount by which
the figure exceeds Six Hundred Fifty Thousand United States Dollars
(US$650,000), whether a negative or a positive sum.

 

III-5

 

7.                                       Effect of Cancellation:

 

It is expressly understood and agreed by the parties that in any case,
if the BUYER cancels this Contract under this Article, the BUYER shall not be
entitled to any liquidated damages or any other recourse unless by means of the
provisions of Article X hereof.

 

(End of Article)

 

III-6

 

ARTICLE IV - APPROVAL OF PLANS AND
DRAWINGS AND INSPECTION DURING

 

CONSTRUCTION

 

1.                                       Approval of Plans and Drawings:

 

The BUILDER shall obtain the approval from the BUYER for the plans and
drawings in accordance with the Specifications.

 

The BUILDER shall submit to the BUYER Three (3) copies of each of
the plans and drawings, the list of which shall be mutually agreed upon between
the parties hereto, for its approval.

 

The BUYER shall, within Twenty-two (22) calendar days after receipt
thereof, return to the BUILDER One (1) copy of such plans and drawings
with the BUYER’S approval or comments (if any) written thereon.

 

If the BUYER shall fail to return the plans and drawings to BUILDER
within the time limit as above provided, the BUILDER shall deem that such plans
and drawings have been approved or confirmed without any comment

 

In the event the Classification Society or any Regulatory Body advises
the BUILDER that it has written comments to the plans and drawings or wishes to
modify the plans and drawings, the BUILDER shall notify the BUYER of such
developments and within two (2) working days of receipt of such
developments, provide the BUYER with copies of the comments or requested
modifications. The BUYER shall within five (5) working days after receipt
notify the BUILDER whether it accepts such comments or modifications. If any
comments are made or modifications requested by the Classification Society or
by another Regulatory Body, the BUILDER will make suitable amendments and
resubmit these to the BUYER for approval.

 

Approval or non approval of a plan or drawing by the BUYER shall in no
way diminish, affect or impair the obligation, guarantee or undertaking of the BUILDER
as regards the design and construction of the VESSEL and to deliver the same in
accordance with the terms hereof.

 

IV-1

 

2.                                       Appointment of BUYER’s Supervisor:

 

The BUYER may send to and maintain at the Shipyard, at the BUYER’s
own cost and expense, one supervisor who shall be duly authorized in writing by
the BUYER (herein called the “Supervisor”) to act on behalf of the BUYER in connection
with the attendance to the tests and inspections relating to the VESSEL, its
machinery, equipment and outfittings, and any other matters for which he is
specifically authorized by the BUYER. The Supervisor may appoint
assistant(s) up to maximum Four (4) persons to attend at the Shipyard to
assist him for the purposes as aforesaid.

 

In addition, the BUYER may appoint the ship’s crew to attend to
the VESSEL in good time prior to and during sea trials throughout until
delivery of the VESSEL.

 

3.                                       Inspection by the Supervisor:

 

The necessary inspections of the VESSEL, its machinery, equipment and
outfittings shall be carried out by the Classification Society, other
applicable regulatory bodies and/or an inspection team of the BUILDER
throughout the entire period of construction in order to ensure that the
construction of the VESSEL is duly performed in accordance with this Contract
and the Specifications. The Supervisor shall have, during construction of the
VESSEL, the right to attend such tests and inspections of the VESSEL, its
machinery and equipment within the premises of either the BUILDER or its
subcontractors and shall have the right to inspect any work in progress or
materials utilized in connection with the construction of the VESSEL, wherever
such work is being done or such materials are stored, Detailed procedures of
the inspection and the tests thereof shall be in accordance with the
Specifications.

 

The BUILDER shall give a reasonable advance notice to the Supervisor of
the date and place of such tests, trials and inspections, which may be
attended by him, including, when relevant, a description of the test, procedure
and level of performance to be reached in order to comply with the
Specifications. Failure by the Supervisor to be present at such tests, trials
and inspections after due notice to

 

IV-2

 

him as aforesaid shall be deemed to be a waiver of the Supervisor’s
right to be present.

 

In case the number of assistants as mentioned hereinabove would not be
sufficient to meet the BUILDER’S schedule of tests, trials and inspection,
the BUILDER shall either reschedule these tests, trials and inspection or may accept
that the BUYER increase the number of assistants as necessary.

 

Upon completion of each test, trial or inspection, the BUILDER shall
provide the Supervisor with a copy of the BUILDER’S report relating to that
test, trial or inspection.

 

If the Supervisor discovers any construction, material or workmanship,
which is not deemed to conform to the requirements of this Contract and/or
the Specifications, the Supervisor shall promptly give the BUILDER a notice in
writing specifying the alleged non-conformity. Upon receipt of such notice from
the Supervisor, the BUILDER shall correct such non-conformity, if the BUILDER
agrees to his view. Any disagreement shall be resolved in accordance with
Paragraph 1 of Article XII.

 

If the Classification Society or the arbitrator enters a determination
in favor of the BUYER, then in such case the BUILDER shall correct such
non-conformity, or in the BUYER’s option the BUILDER shall make fair and
reasonable adjustment of the Contract Price to be mutually agreed between the
BUILDER and the BUYER in lieu of such corrections.

 

The attendance or lack of attendance of of the Supervisor or his
assistants at any test or inspection shall, in no way, diminish or affect the
liability of the BUILDER under this Contract.

 

IV-3

 

4.                                       Facilities:

 

The BUILDER shall furnish the Supervisor and his assistant(s) with
adequate office space and such other reasonable facilities according to the
BUILDER’s practice at or in the immediate vicinity of the Shipyard as may be
necessary to enable them to effectively carry out their duties. The BUYER shall pay for all such facilities
other than office space, at the BUILDER’s normal rate of charge.

 

5.                                       Liability of BUILDER:

 

The Supervisor and his assistant(s) shall at all times be deemed to be
the employees of the BUYER and not of the BUILDER. The BUILDER shall be under
no liability whatsoever to the BUYER, the Supervisor or his assistant(s) for
personal injuries, including death, suffered during the time when he or they
are on the VESSEL, or within the premises of either the BUILDER or its subcontractors,
or are otherwise engaged in and about the construction of the VESSEL, unless,
however, such personal injuries, including death, were caused by a gross
negligence of the BUILDER, or of any of its employees or agents or
subcontractors.

 

Nor shall the BUILDER be under any liability whatsoever to the BUYER,
the Supervisor or his assistant(s) for damage to, or loss or destruction of
property in Korea of the BUYER or of the Supervisor or his assistant(s), unless
such damage, loss or destruction were caused by a gross negligence of the
BUILDER or of any of its employees or agents or subcontractors.

 

6.                                       Responsibility of BUYER:

 

The BUYER shall undertake and assure that the Supervisor shall carry
out his duties hereunder in accordance with the normal shipbuilding practice of
the BUILDER and in such a way so as to avoid any unnecessary increase in
building cost, delay in the construction of the VESSEL, and/or any disturbance
in the construction schedule of the BUILDER.

 

IV-4

 

The BUILDER has the right to request the BUYER to
replace the Supervisor who is deemed unsuitable and unsatisfactory for the
proper progress of the VESSEL’s construction. The BUYER shall investigate the
situation by sending its representative (s) to the Shipyard if necessary, and
if the BUYER considers that such BUILDER’s request is justified, the BUYER
shall effect such replacement as soon as conveniently arrangeable.

 

Without effect to the above, the BUYER and the
BUILDER shall cooperate fully and use best efforts to resolve any design, construction difficulties and problems encountered after
signing this Contract.

 

(End of Article)

 

IV-5

 

ARTICLE V - MODIFICATIONS, CHANGES AND
EXTRAS 

 

1.                                       Modification of Specifications:

 

The Specifications may be modified to a minor extent by written
agreement of the parties hereto, provided that such modifications will not, in
the BUILDER’s reasonable judgment, adversely affect the BUILDER’s planning or
program in relation to the BUILDER’s other commitments, and provided, further,
that the BUYER shall first agree, before such modifications and/or changes are
carried out, to alterations in the Contract Price, the Delivery Date,
deadweight, speed and other terms and conditions of this Contract and
Specifications occasioned by or resulting from such modifications and/or
changes within seven (7) days from the receipt by the BUYER of the BUILDER’s
proposal. The BUILDER has the right to continue construction of the VESSEL on
the basis of the Specifications until agreement as above has been reached but
upon receipt by the BUILDER of a request from the BUYER for a modification the
BUILDER shall as soon as reasonably practical and at the latest within seven (7) days
of the request submit to the BUYER a proposal of adjustment in the Contract
Price, the Delivery Date and any other term of the Contract.

 

An agreement to modify this Contract or the Specifications shall be
effected by an exchange of letters signed by the authorized Representative(s)
of the parties or by an Addendum to this Contract and/or the Specifications.

 

The BUILDER may also make minor changes to the Specifications if
found necessary to suit the Shipyard’s local conditions and facilities, the
availability of materials and equipment., introduction of improved methods or
otherwise, provided that the BUILDER shall first obtain the BUYER’s approval,
which shall not be unreasonably withheld or delayed.

 

V-1

 

2.                                       Changes in Rules of Classification
Society, Regulations, etc.:

 

If, after the date of signing this Contract, any requirements as to the
classification, or as to the rules and regulations to which the
construction of the VESSEL is required to conform, are changed by the
Classification Society or regulatory bodies authorized to make such changes,
the following provisions shall apply unless a waiver of the changed
requirement, rule, regulation or interpretation is obtained pursuant to the
BUYER’s request:

 

(a)                                  If the changes are compulsory for the VESSEL,
any of the parties hereto, upon receipt of information from the Classification
Society or such other regulatory bodies, shall promptly transmit the same to
the other in writing, and the BUILDER shall thereupon incorporate such changes
into the construction of the VESSEL, provided that the BUYER shall first have agreed
to adjustments required by the BUILDER in the Contract Price, the Delivery
Date, deadweight, speed and other terms and conditions of this Contract and the
Specifications occasioned by or resulting from such changes within seven (7) days
from the receipt by the BUYER of the BUILDER’s proposal.

 

(b)                                 If the changes are not compulsory for the
VESSEL, but the BUYER desires to incorporate any of them into the construction
of the VESSEL, the BUYER shall notify the BUILDER of that intention. The
BUILDER may accept such changes, provided that such changes will not in
its reasonable judgment adversely affect the BUILDER’s planning or program in
relation to the BUILDER’s other commitments, and provided, further, that the
BUYER shall first have agreed to adjustments required by the BUILDER in the
Contract Price, the Delivery Date, deadweight, speed and other terms and
conditions of this Contract and the Specifications occasioned by or resulting
from such changes within seven (7) days from the receipt by the BUYER of
the BUILDER’s proposal.

 

V-2

 

Agreement as to any changes under Paragraph 2 of this Article shall
be made in the same manner as provided in Paragraph 1 of this Article for
modifications or changes to the Specifications.

 

Any delay in the construction of the VESSEL caused by the BUYER’s delay
in making a decision or agreement outside the time limits set out above shall
constitute a permissible delay under this Contract.

 

3.                                       Substitution of Materials:

 

If any of the materials or equipment required by the Specifications or
otherwise under this Contract for the construction of the VESSEL are in short
supply or cannot be procured in time to maintain the Delivery Date of the
VESSEL or are unreasonably high in price as compared with prevailing
international market rates, the BUILDER may, provided that the BUYER shall so
agree in writing (which agreement shall not be unreasonably withheld), supply
other materials or equipment of equal quality and effect capable of meeting the
requirements of the Specification and this Contract. Any agreement as to
substitution of materials or equipment shall be effected in the manner as
provided in Paragraph 1 of this Article.

 

(End of Article)

 

V-3

 

ARTICLE VI - TRIALS AND ACCEPTANCE 

 

1.                                       Notice:

 

The sea trial shall start when the VESSEL is reasonably completed
according to the Specifications.

 

The BUILDER shall give the BUYER at least Twenty (20) days estimated
prior notice and Seven (7) days confirming prior notice by telefax of the
time and place of the trial run of the VESSEL, and the BUYER shall promptly
acknowledge receipt of such notice. The BUYER shall be entitled to have its
Supervisor and such assistants of his as may be necessary on board the
VESSEL to witness such trial run. Failure in attendance of the BUYER’s
Supervisor at the trial run of the VESSEL for any reason whatsoever after due
notice to the BUYER as above provided shall be deemed to be a waiver by the
BUYER of its right to have its Supervisor on board the VESSEL at the trial run,
and the BUILDER may conduct the trial run without attendance of the BUYER’s
Supervisor subject always to a representative of the Classification Society
being in attendance throughout, and in such case the BUYER shall be obligated
to accept the VESSEL on the basis of a certificate of the BUILDER and the
Classification Society that the VESSEL, upon its trial run, is found to conform to
this Contract and the Specifications.

 

2.                                       Weather Condition:

 

The trial run shall be carried out under the weather condition, which
is deemed favorable enough by the judgment of the BUILDER in accordance with
the Specifications. In the event of unfavorable weather on the date specified
for the trial run, the same shall take place on the first available day
thereafter that the weather condition permits. It is agreed that, if during the
trial run of the VESSEL, the weather should suddenly become so unfavorable that
orderly conduct of the trial run can no longer be continued, the trial run
shall be discontinued and postponed until the first favorable day next
following, unless the BUYER shall assent in writing to acceptance of the VESSEL
on the basis of the trial run already made before such discontinuance has
occurred.

 

VI-1

 

Any delay of trial run caused by such unfavorable weather condition
shall operate to postpone the Delivery Date by the period of the delay involved
and such delay shall be deemed as permissible delay in the delivery of the
VESSEL.

 

3.                                       How Conducted:

 

(a)                                  The VESSEL shall run the official trial trip
in the manner as specified in the Specifications.

 

(b)                                 All expenses in connection with the trial run
are to be for account of the BUILDER and the BUILDER shall provide, at its own
expense, the necessary crew to comply with conditions of safe navigation.

 

4.                                       Method of Acceptance or Rejection:

 

(a)                                  Upon completion of the trial run, the BUILDER
shall give the BUYER a notice by telefax of completion of the trial run, as and
if the BUILDER considers that the results of trial run indicate conformity of
the VESSEL to this Contract and the Specifications. The BUYER shall, within
Five(5) days after receipt of such notice from the BUILDER, notify the
BUILDER by telefax of its acceptance or rejection of the VESSEL’s conformity to
this Contract and the Specifications.

 

(b)                                 However, should the result of the trial run
show that the VESSEL, or any part or equipment thereof, does not conform to
the requirements of this Contract and/or the Specifications, or if the BUILDER
is in agreement to non conformity as specified in the BUYER’s notice of
rejection, then, the BUILDER shall take necessary steps to correct such
non-conformity.

 

Upon completion of correction of such non-conformity, and re-test or
trial if necessary, the BUILDER shall give the BUYER a notice thereof by
telefax.

 

The BUYER shall, within Three(3) days after receipt of such notice
from the BUILDER, notify the BUILDER of its acceptance or rejection of the
VESSEL.

 

VI-2

 

However, the BUYER shall not be entitled to reject the VESSEL by reason
of any minor or insubstantial defect or non-conformity judged from the
viewpoint of the normal shipbuilding practice but in such case, the BUILDER
shall correct and/or remedy such minor or insubstantial defect or non-conformity
as soon as possible during the Warranty Period.

 

(c)                                  In any event that the BUYER rejects the
VESSEL, the BUYER shall indicate in detail in its notice of rejection in what
respect the VESSEL, or any part or equipment thereof does not conform to
this Contract and/or the Specifications.

 

(d)                                 In the event that the BUYER fails to notify
the BUILDER by telefax of the acceptance of or the rejection together with the
reason therefor of the VESSEL within the period as provided in the above
Sub-Paragraph (a) or (b), the BUYER shall be deemed to have accepted the
VESSEL.

 

(e)                                  Any dispute between the BUILDER and the BUYER
as to the conformity or non-conformity of the VESSEL to the requirements of
this Contract and/or the Specifications shall be submitted for final decision
in accordance with Article XII hereof.

 

5.                                       Effect of Acceptance:

 

Acceptance of the VESSEL as above provided shall be final and binding
so far as conformity of the VESSEL to this Contract and the Specifications is
concerned and shall preclude the BUYER from refusing formal delivery of the
VESSEL as hereinafter provided, if the BUILDER complies with all other
procedural requirements for delivery as provided in Article VII hereof.
However, the BUYER’s acceptance of the VESSEL shall not affect the BUYER’s
right in 4. (b) above or under Article IX hereof.

 

VI-3

 

6.                                       Disposition of Surplus Consumable Stores

 

Any fuel oil, fresh water or other consumable stores furnished and paid
for by the BUILDER for trial runs remaining on board the VESSEL in storage
tanks, at the time of acceptance of the VESSEL by the BUYER, shall be bought by
the BUYER from the BUILDER at the BUILDER’s original purchase price for such
supply in Korea and the payment by the BUYER thereof shall be made at the time
of delivery of the VESSEL.

 

The BUILDER shall pay the BUYER at the time of delivery of the VESSEL
an amount for the consumed quantity during trial run of any lubricating oil and
greases which were furnished and paid for by the BUYER at the BUYER’s original
purchase price thereof.

 

(End of Article)

 

VI-4

 

 

ARTICLE VII - DELIVERY

 

1.                                       Time and Place:

 

The VESSEL shall be delivered safely afloat by the BUILDER to the BUYER
at the Shipyard on or before 28th of May, 2008, after completion of
satisfactory trials and acceptance by the BUYER in accordance with the terms of
Article VI, except that, in the event of delays in the construction of the
VESSEL or any performance required under this Contract due to causes which
under the terms of this Contract permit postponement of the date for delivery,
the aforementioned date for delivery of the VESSEL shall be postponed
accordingly.

 

The aforementioned date, or such later date to which the requirement of
delivery is postponed pursuant to such terms, is herein called the “Delivery
Date”.

 

2.                                       When and How Effected:

 

Provided that the BUILDER and the BUYER shall have fulfilled all of
their obligations stipulated under this Contract, the delivery of the VESSEL
shall be effected forthwith by the concurrent delivery by each of the parties
hereto to the other of the signed PROTOCOL OF DELIVERY AND ACCEPTANCE,
acknowledging delivery of the VESSEL by the BUILDER and acceptance thereof by
the BUYER.

 

3.                                       Documents to be delivered to BUYER:

 

Upon delivery and acceptance of the VESSEL, the BUILDER shall deliver
to the BUYER the following documents, which shall accompany the PROTOCOL OF
DELIVERY AND ACCEPTANCE:

 

(a)                                  PROTOCOL OF TRIALS of the VESSEL made pursuant
to the Specifications.

 

(b)                                 PROTOCOL OF INVENTORY of the equipment of the
VESSEL, including spare parts and the like, as specified in the Specifications.

 

VII-1

 

(c)                                  PROTOCOL OF STORES OF CONSUMABLE NATURE
referred to under Paragraph 6 of Article VI hereof.

 

(d)                                 PROTOCOL OF DEADWEIGHT DETERMINATION AND
INCLINING EXPERIMENT as stipulated in the Specifications

 

(e)                                  ALL CERTIFICATES including the BUILDER’S
CERTIFICATE required to be furnished upon delivery of the VESSEL pursuant to
this Contract and the Specifications.

 

It is agreed that if, through no fault on the part of the BUILDER,
the Classification Certificate and/or other certificates are not available at
the time of delivery of the VESSEL, and if the absence thereof does not impede
the BUYER’s full and immediate operation, navigation or the management of the
VESSEL, provisional certificates shall be accepted by the BUYER, provided that
the BUILDER shall furnish the BUYER with the formal certificates as promptly as
possible after such certificates have been issued and in any event not later
than the date on which the validity of the provisional certificates expires.
All certificates whether provisional or final shall be full term certificates
without any recommendations or any qualifications, unless otherwise agreed by
the parties.

 

Application and certificate for statutory inspections for the registry
of the VESSEL shall be arranged by the BUYER at its expense.

 

(f)                                    DECLARATION OF WARRANTY of the BUILDER that
the VESSEL is delivered to the BUYER free and clear of any liens, charges,
claims, mortgages, or other encumbrances upon the BUYER’s title thereto, and in
particular that the VESSEL is absolutely free of all burdens in the nature of imposts,
taxes or charges imposed by Korean Governmental Authorities, as well as of all
liabilities of the BUILDER to its subcontractors, employees and crew, and of
the liabilities arising from the operation of the VESSEL in trial runs, or
otherwise, prior to delivery.

 

VII-2

 

(g)                                 FINISHED AS BUILT DRAWING AND PLANS and MANUALS
pertaining to the VESSEL as stipulated in the Specifications

 

(h)                                 COMMERCIAL INVOICE.

 

(i)                                     BILL OF SALE

 

4.                                       Tender of VESSEL:

 

If the BUYER fails to take delivery of the VESSEL after completion
thereof according to this Contract and the Specifications without any
justifiable reason, the BUILDER shall have the right to tender the VESSEL to
the BUYER for delivery for the purpose of Article XI.I (c). Such tender
shall be made by the BUILDER by a notice to the BUYER stating that the VESSEL
is tendered for delivery pursuant to Article VII. 4 of the Contract.

 

5.                                       Title and Risk:

 

Title to and risk of loss of the VESSEL shall pass to the BUYER only
upon the delivery and acceptance thereof having been completed as stated above;
it being expressly understood that, until such delivery is effected, title to
and risk of loss of the VESSEL and her equipment shall be in the BUILDER.

 

6.                                       Removal of VESSEL:

 

The BUYER shall take possession of the VESSEL immediately upon delivery
and acceptance thereof and shall remove the VESSEL from the premises of the
Shipyard within Three(3) days after delivery and acceptance thereof is
effected.

 

If the BUYER shall not remove the VESSEL from the premises of the
Shipyard within the aforesaid Three(3) days, in such event, the BUYER
shall pay to the BUILDER the reasonable mooring charges of the VESSEL.

 

(End of Article)

 

VII-3

 

ARTICLE VIII
- DELAYS AND EXTENSION OF TIME FOR DELIVERY (FORCE MAJEURE)

 

1.                                       Causes of Delay (Force Majeure):

 

If, at any time either the construction or delivery of the VESSEL or
any performance required hereunder as a prerequisite to the delivery thereof is
delayed by any of the following events; namely war, acts of state or
government, blockade, revolution, insurrections, mobilization, civil commotion,
riots, strikes, sabotage, lockouts, Acts of God or the public enemy, plague or
other epidemics, quarantines, prolonged failure of electric current, freight
embargoes, or defects in major forgings or castings which could not have been
detected by the BUILDER using reasonable care nor caused by the neglect of the
BUILDER or shortage of materials, machinery or equipment or inability to obtain
delivery or delays in delivery of materials, machinery or equipment, due to an
event of the nature as described in this Article affecting such supplier
or subcontractor, provided that at the time of ordering the same could
reasonably be expected by the BUILDER to be delivered in time, or defects in
materials, machinery or equipment which could not have been detected by the
BUILDER using reasonable care, or earthquakes, tidal waves, typhoons,
hurricanes, prolonged or unusually severe weather conditions or delay in the
construction of the BUILDER’s other newbuildings due to any such causes as
described in this Article which in turn delay the construction of the
VESSEL in view of the Shipyard’s overall building programme or the BUILDER’s
performance under this Contract, or by destruction of the premises or works of
the BUILDER or its sub-contractors such as to effect performance hereunder, or
of the VESSEL, or any part thereof, by fire, landslides, flood, lightning,
explosion, or other causes whatsoever beyond the control of the BUILDER, or its
sub-contractors, as the case may be, then, in the event of delays due to
the happening of any of the aforementioned contingencies, the Delivery Date of
the VESSEL under this Contract shall be extended for a period of time by which
the overall construction programme has actually been delayed, the BUILDER being
obliged to reschedule its construction programme wherever possible to
minimize any delay as far as possible.

 

VIII-1

 

2.                                       Notice of Delay:

 

Within Twenty (20) days after the date of occurrence of any cause of
delay, on account of which the BUILDER claims that it is entitled under this
Contract to a postponement of the Delivery Date, the BUILDER shall notify the
BUYER by telefax of the date when such cause of delay occurred. Likewise,
within Twenty (20) days after the date of ending of such cause of delay, the
BUILDER shall notify the BUYER by telefax of the date when such cause of delay
ended.

 

The BUILDER shall also notify the BUYER of the period, by which the
Delivery Date is postponed by reason of such cause of delay, as soon as it may be
determined. If the BUILDER does not give the timely advice as above, the
BUILDER shall lose the right to claim such delays as permissible delay.

 

Failure of the BUYER to acknowledge to the BUILDER’s claim for
postponement of the Delivery Date within Seven(7) days after receipt by
the BUYER of such notice of claim shall be deemed to be a waiver by the BUYER
of its right to object to such postponement of the Delivery Date..

 

3.                                       Definition of Permissible Delay:

 

Delays on account of such causes as specified in Paragraph 1 of this Article and
any other delay of a nature which under the terms of this Contract permits
postponement of the Delivery Date shall be understood to be permissible delays
and are to be distinguished from unauthorized delays on account of which the
Contract Price is subject to adjustment as provided for in Article III
hereof.

 

4.                                       Right to Cancel for Excessive Delay:

 

If the total accumulated time of all delays claimed by the BUILDER on
account of the causes specified in Paragraph 1 of this Article, excluding other
delays of the nature which under the terms of this Contract permit postponement
of the Delivery Date, amounts to Two Hundred and Ten (210) days or more, then,
in

 

VIII-2

 

such event, the BUYER may cancel this Contract in accordance with
the provisions of Article X hereof.

 

The BUILDER may, at any time after the accumulated time of the
aforementioned delays justifying cancellation by the BUYER, demand in writing
that the BUYER shall make an election, in which case the BUYER shall, within
Fourteen (14) days after such demand is received by the BUYER, either notify
the BUILDER of its intention to cancel this Contract, or consent to a
postponement of the Delivery Date to an agreed specific future date; it being
understood and agreed by the parties hereto that, if any further delay occurs
on account of causes justifying cancellation as specified in this Article, the
BUYER shall have the same right of cancellation upon the same terms as herein
above provided.

 

(End of Article)

 

VIII-3

 

ARTICLE IX - WARRANTY OF QUALITY

 

1.                                       Guarantee:

 

The BUILDER, for the period of Twelve(12) months after delivery of the
VESSEL (hereinafter called “Guarantee Period”), guarantees the VESSEL and her
engine, including all parts and equipment manufactured, furnished or installed
by the BUILDER under this Contract, and including the machinery, equipment and
appurtenances thereof, under the Contract but excluding any item which is
supplied by the BUYER or by any other bodies on behalf of the BUYER, against
all defects discovered within the Guarantee Period which are due to faulty
design, defective material, and/or poor workmanship or negligent or other
improper acts or omissions on the part of the BUILDER or its
subcontractors (hereinafter called the “Defect” or “Defects”) and are not a
result of accident, ordinary wear and tear, misuse, mismanagement, negligent or
other improper acts or omissions or neglect on the part of the BUYER, its
employee or agents.

 

In addition to the foregoing, the BUILDER shall assist the BUYER in
securing from the paint manufacturer(s) a guarantee direct to the BUYER for the
cargo tank and seawater ballast coating for a period of twenty-four (24) months
in addition to the BUILDER’S aforementioned twelve (12) months guarantee.

 

In the event that longer warranties are available from, third party
suppliers of materials, parts and/or equipment at no additional cost then the
BUILDER shall secure such extended warranties.

 

If a design or equipment has been implemented or introduced on a
sistership, which has been acknowledged as a guarantee item, such change shall
be also introduced for the VESSEL, if not yet delivered as far as it is practically
possible to carry out such change before delivery of the VESSEL, or if
delivered within the Guarantee Period.

 

IX-1

 

The BUILDER shall ensure wherever possible that warranties and the like
provided by Suppliers of goods, materials, parts, and equipment, and any
Subcontractors who may be approved, are assignable to the BUYER or its
assignee and upon the BUYER’s request the BUILDER shall assign to the BUYER any
such rights as it may have including any right to pursue any claim under
the relevant supply or sub contract.

 

2.                                       Notice of Defects:

 

The BUYER shall notify the BUILDER in writing, or by telefax of any
defect for which claim is made under this guarantee, as promptly as possible
after discovery thereof. The BUYER’s notice shall describe in detail the
nature, cause and extent of the Defects.

 

The BUILDER shall have no obligation for any Defect discovered prior to
the expiry date of the Guarantee Period, unless notice of such Defect is
received by the BUILDER not later than Ten (10) days after such expiry
date.

 

3.                                       Remedy of Defects:

 

(a)                                  The BUILDER shall remedy, at its expense, any
Defect against which the VESSEL is guaranteed under this Article, by making all
necessary repairs or replacements at the Shipyard.

 

(b)                                 However, if it is impracticable to bring the
VESSEL to the Shipyard, the BUYER may cause the necessary repairs or
replacements to be made elsewhere which is deemed suitable for the purpose,
provided that, in such event, the BUILDER may forward or supply
replacement parts or materials to the VESSEL, unless forwarding or supplying
thereof the VESSEL would impair or delay the operation of working schedule of
the VESSEL. In the event that the BUYER proposes to cause the necessary repairs
or replacements for the VESSEL to be made at any other shipyard or works than the
Shipyard, the BUYER shall first, but in all events as soon as possible, give
the BUILDER a notice in writing or by telefax confirmed in writing of

 

IX-2

 

the time and place when and where such repairs will be made, and if the
VESSEL is not thereby delayed, or her operation or working schedule is not
thereby impaired, the BUILDER shall have the right to verify by its own
representative(s) the nature, cause and extent of the Defects complained of.

 

The BUILDER shall, in such case, promptly advise the BUYER by telefax
after such examination has been completed, of its acceptance or rejection of
the Defects as ones that are covered by the guarantee herein provided. Upon the
BUILDER’S acceptance of the Defects as justifying remedy under this Article, or
upon award of the arbitration so determining, the BUILDER shall reimburse the
BUYER the documented expenses incurred by the BUYER for such repairs or
replacements but such reimbursement shall not exceed the reasonably estimated
cost of carrying out the warranty work at the Shipyard under the same working
conditions.

 

The guarantee works shall be settled regularly during the Guarantee
Period and the actual reimbursement for the guarantee shall be made in a lump
sum after the expiry of the Guarantee Period.

 

(c)                                  In any case, the VESSEL shall be taken, at
the BUYER’S cost and responsibility, to the place elected, ready in all
respects for such repairs or replacement it being understood that the
engineering, calculations, dismantling, staging, cleaning, tooling, handling,
testing, the supply of parts, dockage if needed, provided such works are
directly related to those repairs and/or replacements, shall be considered as part of
the repair or replacement process to be carried out by the BUILDER.

 

In the event mat it is necessary for the BUILDER to forward a
replacement for a defective part under this guarantee, replacement parts
shall be delivered to the BUYER, onboard the VESSEL, at the BUYER’S designated
port by air, sea, road or rail freight at the BUILDER’S expense to such
location as is directed by the BUYER, the method of transportation being
determined by the urgency with which the replacement is required.

 

IX-3

 

The BUILDER reserves the option to retrieve, at the BUILDER’S cost, any
of the replaced equipment/parts in case defects are remedied in accordance with
the provisions in this Article.

 

(d)                                 Any dispute under this Article shall be
referred to arbitration in accordance with the provisions of Article XII
hereof.

 

4.                                       Extent of BUILDER’S Responsibility:

 

(a)                                  The BUILDER shall have no responsibility or
liability for any other defect whatsoever in the VESSEL than the Defects
specified in Paragraph 1 of this Article. Nor the BUILDER shall in any
circumstance be responsible or liable for any consequential or special loss,
damage or expense including but not limited to loss of time, loss of profit of
earning or demurrage directly or indirectly occasioned to the BUYER by reason
of the Defects specified in Paragraph 1 of this Article or due to repairs
or other works done to the VESSEL to remedy such Defects.

 

(b)                                 The BUILDER shall not be responsible for any
defect in any part of the VESSEL which may, subsequently to delivery of
the VESSEL, have been replaced or repaired in any way by any other contractor,
or for any defect which have been caused or aggravated by omission or improper
use and maintenance of the VESSEL on the part of the BUYER, its servants
or agents or by ordinary wear and tear or by any other beyond control of the
BUILDER.

 

(c)                                  The guarantee contained as hereinabove in
this Article replaces and excludes any other liability, guarantee,
warranty and/or condition imposed or implied by the law, customary, statutory
or otherwise, by reason of the construction and sale of the VESSEL by the
BUILDER for and to the BUYER.

 

IX-4

 

5.                                       Guarantee Engineer:

 

The BUILDER shall have the right to appoint a Guarantee Engineer to
serve on the VESSEL as its representative for a period of Three(3) months
from the date the VESSEL is delivered. However, if the BUYER and the BUILDER
shall deem it necessary to keep the Guarantee Engineer on the VESSEL for a
longer period, then he shall remain on board the VESSEL after the said Three(3) months,
but not longer than Six(6) months from the delivery of the VESSEL.

 

The BUYER, and its employees, shall give such Guarantee Engineer full
cooperation in carrying out his duties as the representative of the BUILDER on
board the VESSEL.

 

The BUYER shall accord the Guarantee Engineer treatment comparable to
the VESSEL’s Chief Engineer, and shall provide board and lodging at no cost to
the BUILDER and/or the Guarantee Engineer.

 

While the Guarantee Engineer is on board the VESSEL, the BUYER shall
pay to the BUILDER the sum of Five Thousand United States Dollars (US$5,000.-)
per month as a compensation for a part of cost and charges to be borne by
the BUILDER in connection with Guarantee Engineer and also shall pay the
expenses of his repatriation to Seoul, Korea by air upon termination of his
service, the expenses of his communication with the BUILDER incurred in
performing his duties and expenses, if any, of his medical and hospital care in
the VESSEL’s hospital.

 

Pertaining to the detailed particulars of this Paragraph, an agreement
will be made according to this effect between the parties hereto upon delivery
of the VESSEL.

 

(End of Article)

 

IX-5

 

ARTICLE X - CANCELLATION BY BUYER

 

1.                                       BUILDER’s Default and Effect of Default

 

The BUYER shall be entitled but not bound to declare the BUILDER in
default of this CONTRACT in any one of the following cases

 

(a)                                  the BUILDER is declared bankrupt by order of
any court of competent jurisdiction, or files a petition of cessation of
payments;

 

(b)                                 the appointment of a receiver over all or a
substantial part of the BUILDER’S assets;

 

(c)                                  an effective resolution is passed for the
BUILDER’S voluntary winding up (except for the purposes of reorganization, merger
or amalgamation) or compulsory liquidation;

 

(d)                                 the conclusion of a scheme of arrangement or
other voluntary composition between the BUILDER and his creditors;

 

(e)                                  the VESSEL becomes, before delivery, an
actual or constructive or compromised or agreed or arranged total loss and when
the BUILDER is not covered by the insurance policy as per Article XVII;

 

(f)                                    the BUILDER, without prior written consent of
the BUYER, removes the VESSEL from the Shipyard or assigns, sub-lets or
subcontracts performance of the whole or part of its obligations, except
as provided for in this Contract or as agreed by BUYER; or

 

(g)                                 the BUILDER fails to tender the VESSEL upon
completion of the VESSEL.

 

If the BUILDER shall be in any default as provided for herein, the
BUYER may at its option, cancel this CONTRACT.

 

X-1

 

2                                          Notice:

 

The payments made by the BUYER prior to delivery of the VESSEL shall be
in the nature of advances to the BUILDER, and in the event that the VESSEL
after sea trial is rejected by the BUYER or the Contract is cancelled by the
BUYER in accordance with the terms of this Contract under and pursuant to any
of the provisions of this Contract specifically permitting the BUYER to do so,
then the BUYER shall notify the BUILDER in writing or by telefax confirmed in
writing, and such cancellation shall be effective as of the date when notice
thereof is received by the BUILDER.

 

3.                                       Refund by BUILDER:

 

In case the BUILDER receives the notice stipulated in Paragraph 2 of
this Article, the BUILDER shall promptly refund to the BUYER the full amount of
all sums paid by the BUYER to the BUILDER on account of the VESSEL together
with interest thereon, unless the BUILDER disputes same and proceeds to
arbitration under the provisions of Article XII hereof.

 

In such event, the BUILDER shall pay the BUYER interest at the rate of
Seven percent (7%) per annum on the amount required herein to be refunded to
the BUYER, computed from the dates following on which such sums were paid by
the BUYER to the BUILDER to the date of remittance by transfer of such refund
to the BUYER by the BUILDER., provided, however, that if the said cancellation by
the BUYER is made under the provisions of Paragraph 4 of Article VIII
hereof, then in such event the BUILDER shall not be required to pay any
interest.

 

As security for refund of installments prior to delivery of the VESSEL,
the BUILDER shall furnish the BUYER within Ninety (90) calendar days after
signature of this Contract with a letter of guarantee covering the amount of
such pre-delivery installments and issued by the BUILDER’s Bank in favour of
the BUYER. Such letter of guarantee shall have substantially the same form and
substance as Exhibit “A” annexed hereto.

 

X-2

 

4.                                       Discharge of Obligations:

 

Upon such refund by the BUILDER to the BUYER, all obligations, duties
and liabilities of each of the parties hereto to the other under this Contract
shall be forthwith completely discharged.

 

(End of Article)

 

X-3

 

ARTICLE XI - BUYER’s DEFAULT

 

1.                                       Definition of BUYER’s Default:

 

The BUYER shall be deemed to be in default of its performance of
obligations under this Contract in the following cases:

 

(a)                                  If the Second or Third Installment is not
paid by the BUYER to the BUILDER within Three (3) banking days after such
installment becomes due and payable as provided in Article II hereof (Five
(5) banking days in case of the First Installment);

 

or

 

(b)                                 If the Fourth Installment is not deposited by
the BUYER at the BUILDER’s bank at least Three (3) business days prior to
the anticipated delivery date of the VESSEL as provided In Article II
hereof;

 

or

 

(c)                                  If the BUYER, when the VESSEL is duly
tendered for delivery by the BUILDER in accordance with the provisions of this
Contract, fails to accept the VESSEL within Five (5) days from the
tendered date without any specific and valid ground thereof under this
Contract;

 

2.                                       Effect of Default on or before Delivery of
VESSEL:

 

(a)                                  Should the BUYER make default in payment of
any installment of the Contract Price on or before delivery of the VESSEL, the
BUYER shall pay the installment(s) in default plus accrued interest thereon at
the rate of Seven percent(7%) per annum computed from the due date of such
installment to the date when the BUILDER receives the payment, and, for the
purpose of Paragraph 1 of Article VII hereof the Delivery Date of the
VESSEL shall be automatically extended by the period of continuance of such
default by the BUYER. In any event of default by the BUYER, the BUYER shall
also pay all charges and expenses incurred by the BUILDER in consequence of
such default.

 

XI-1

 

(b)                                 If any default by the BUYER continues for a
period of Twenty (20) days, the BUILDER may, at its option, cancel this
Contract by giving notice of such effect to the BUYER by telefax confirmed in
writing.

 

Upon dispatch by the BUILDER of such notice of cancellation, this
Contract shall be forthwith cancelled and terminated. In the event of such
cancellation of this Contract, the BUILDER shall be entitled to retain any
installment or installments already paid by the BUYER to the BUILDER on account
of this Contract and the BUYER’s Supplies, if any.

 

3.                                       Disposal of VESSEL by BUILDER upon BUYER’s
Default:

 

(a)                                  In the event that this Contract is cancelled
by the BUILDER under the provisions of Paragraph 2(b) of this Article, the
BUILDER may, at its sole discretion, either complete the VESSEL and sell the
same, or sell the VESSEL in its incomplete state, free of any right or claim of
the BUYER. Such sale of the VESSEL by the BUILDER shall be either by public
auction or private contract in good faith at the BUILDER’s sole discretion and
on such terms and conditions as the BUILDER shall deem fit.

 

(b)                                 In the event of such sale of the VESSEL, the amount of the sale received
by the BUILDER shall be applied firstly to all expenses attending such sale or otherwise
incurred by the BUILDER as a result of the BUYER’s default, secondly to the
payment of all costs and expenses of construction of the VESSEL incurred by the
BUILDER less BUYER’s Supplies and the installments already paid by the BUYER
and the compensation to the BUILDER for profit due to cancellation of this
Contract, and finally to the repayment to the BUYER without interest, if any
balance is obtained.

 

(c)                                  If the proceeds of sale are insufficient to pay
such total costs and loss of profit as aforesaid, the BUYER shall promptly pay
the deficiency to the BUILDER upon request.

 

(End of Article)

 

XI-2

 

ARTICLE XII - ARBITRATION

 

1.                                       Decision by the Classification Society:

 

If any dispute arises between the parties hereto in regard to the
design and/or construction of the VESSEL, its machinery and equipment, and/or
in respect of the materials and/or workmanship thereof and/or thereon, and/or
in respect of interpretations of this Contract or the Specifications, the
parties may by mutual agreement refer the dispute to the Classification
Society or to such other expert as may be mutually agreed between the
parties hereto, and whose decision shall be final, conclusive and binding upon
the parties hereto.

 

2.                                       Proceedings of Arbitration:

 

In the event that the parties hereto do not agree to settle a dispute
according to Paragraph 1 of this Article and/or in the event of any other
dispute of any kind whatsoever between the parties and relating to this
Contract or its cancellation or any stipulation herein, such dispute shall be
submitted to arbitration in London. Each party shall appoint an arbitrator and
a third by the two arbitrators so appointed.

 

If the two arbitrators are unable to agree upon an third arbitrator
within Twenty(20) days after appointment of the second arbitrator, then either
of the two arbitrators or the parties may apply to the President for the
tune being of the London Maritime Arbitrators Association to appoint the third
arbitrator, and the three arbitrators shall constitute the board of
arbitration.

 

Such arbitration shall be in accordance with and subject to the
provisions of the Arbitration Act 1996 of the United Kingdom or any statutory
modification or re-enactment thereof for the time being in force.

 

Either party may demand arbitration of any such dispute by giving
notice to the other party. Any demand for arbitration by either of the parties
hereto shall state the name of the arbitrator appointed by such party and shall
also identify the dispute for which such party is demanding arbitration.

 

Within Fourteen (14) days after receipt of notice of such demand for
arbitration,

 

XII-1

 

the other party shall in turn appoint a second arbitrator and give
notice in writing of such appointment to the party demanding arbitration. If a
party fails to appoint its arbitrator as aforementioned the party requesting
arbitration may give a second notice in writing to the other party
requiring them to appoint their arbitrator. If they fails to do so within seven
(7) days following receipt of the second notice the party failing to
appoint an arbitrator shall be deemed to have accepted and appointed, as its
own arbitrator, the arbitrator appointed by the party demanding arbitration and
the arbitration shall proceed before this sole arbitrator who alone in such
event shall constitute the Arbitration Board.

 

The award of the arbitrators shall be final and binding on both
parties.

 

3.                                       Work to Continue during Arbitration:

 

Work under this Contract shall continue during the arbitration of any
dispute, unless otherwise mutually agreed between the BUYER and the BUILDER.

 

4.                                       Expenses:

 

The Arbitration Board shall determine which party shall bear the
expenses of the arbitration or the portion of such expenses which each party
shall bear.

 

5.                                       Entry in Court:

 

In case of failure by either party to respect the award of the
arbitration, the judgment may be entered in any proper court having
jurisdiction thereof.

 

6.                                       Alteration of Delivery Date:

 

In the event of reference to arbitration of any dispute arising out of
matters occurring prior to delivery of the VESSEL, the award may include
any postponement of the Delivery Date, which the Arbitration Board may deem
appropriate.

 

(End of Article)

 

XII-2

 

ARTICLE XIII - SUCCESSOR AND ASSIGNS

 

Neither of the parties hereto shall assign this Contract to any other
individual or company unless prior consent of the other party is given in
writing. Should circumstances permit with or without alteration of the terms
and conditions of this Contract, such consent shall not be unreasonably
withheld by either party.

 

Notwithstanding the foregoing the BUYER shall be entitled to assign
this Contract without the need to obtain the consent of the BUILDER either
pursuant to an assignment by way of security to a bank or financial institution
providing credit accommodation to the BUYER in connection with the VESSEL or to
any other company associated with the BUYER (being a company under common
ownership, management or control of the BUYER or the beneficial owners of the
BUYER).

 

In the event of any assignment pursuant to the terms of this Contract,
the assignee shall succeed to all of the rights and obligations of the assignor
under this Contract and the assignor shall remain responsible for the
fulfillment of this Contract.

 

In the event of the assignment from the BUYER to any other individual
or company (other than to a bank or financial institution by way of security as
aforesaid) the BUILDER shall be entitled to request a Performance Guarantee
from the BUYER having same form and contents as Exhibit “B” annexed
hereto.

 

(End of Article)

 

XIII-1

 

ARTICLE XIV - TAXES AND DUTIES

 

1.                                       Taxes and Duties Incurred in Korea:

 

The BUILDER shall bear and pay all taxes, duties, stamps and fees
incurred in Korea in connection with execution and/or performance of this
Contract as the BUILDER, except for any taxes and duties imposed in Korea upon
the BUYER’s Supplies.

 

2.                                       Taxes and Duties Incurred outside Korea:

 

The BUYER shall bear and pay all taxes, duties, stamps and fees
incurred outside Korea in connection with execution and/or performance of this
Contract as the BUYER, except for taxes and duties imposed upon those items to
be procured by the BUILDER for construction of the VESSEL.

 

(End of Article)

 

XIV-1

 

ARTICLE XV - PATENTS, TRADEMARKS,
COPYRIGHTS, ETC.

 

1.                                       Patents, Trademarks and Copyrights:

 

Machinery and equipment of the VESSEL may bear the patent number
trademarks or trade names of the manufacturers. The BUILDER shall defend
without any limitation of time and hold harmless the BUYER from patent
liability or claims of patent infringement of any nature or kind, including
costs and expenses for, or on account of any patented or patentable invention
made or used in the performance of this Contract and also including costs and
expenses of litigation, if any.

 

Nothing contained herein shall be construed as transferring any patent
or trademark rights or copyrights in equipment covered by this Contract, and
all such rights are hereby expressly reserved to the true and lawful owners
thereof. The BUILDER’s warranty hereunder does not extend to the BUYER’s
Supplies.

 

2.                                       General Plans, Specifications and Working
Drawings:

 

The BUILDER retains all rights with respect to the Specifications, and
plans and working drawings, technical descriptions, calculations, test results
and other data, information and documents concerning the design and
construction of the VESSEL and the BUYER undertakes therefore not to disclose
the same or divulge any information contained therein to any third parties,
without the prior written consent of the BUILDER, except where it is necessary
for usual operation, repair and maintenance of the VESSEL or for the sale of
the VESSEL or for raising finance or for enforcing its rights under this
CONTRACT.

 

(End of Article)

 

XV-1

 

ARTICLE XVI - BUYER’s SUPPLIES 

 

1.                                       Responsibility of BUYER:

 

(a)                                  The BUYER shall, at its own risk, cost and
expense, supply and deliver to the BUILDER all of the items to be furnished by
the BUYER as specified in the Specifications (herein called the BUYER’s
Supplies) at warehouse or other storage of the Shipyard in the proper condition
ready for installation in or on the VESSEL, in accordance with the time schedule designated
and advised by the BUILDER to the BUYER.

 

(b)                                 In order to facilitate installation by the
BUILDER of the BUYER’s Supplies in or on the VESSEL, the BUYER shall furmish
the BUILDER with necessary specifications, plans, drawings, instruction books,
manuals, test reports and certificates required by the rules and
regulations of the Specifications. If so requested by the BUILDER, the BUYER
shall, without any charge to the BUILDER, cause the representatives of the
manufacturers of the BUYER’s Supplies to assist the BUILDER in installation
thereof in or on the VESSEL and/or to carry out installation thereof by
themselves or to make necessary adjustments at the Shipyard.

 

(c)                                  Any and all of the BUYER’s Supplies shall be
subject to the BUILDER’s reasonable right of rejection, as and if they are
found to be unsuitable or in improper condition for installation.

 

(d)                                 Should the BUYER fail to deliver any of the
BUYER’s Supplies within the time designated, the Delivery Date shall be
extended for a period, which actually caused the delay in the delivery of the
VESSEL.

 

(e)                                  If delay in delivery of any of the BUYER’s
Supplies exceeds thirty (30) days, then, the BUILDER shall be entitled to
proceed with construction of the VESSEL without installation thereof in or on
the VESSEL as hereinabove provided, and the BUYER shall accept and take
delivery of the VESSEL so

 

XVI-1

 

constructed, unless such delay is caused by Force Majeure. in which
case the provision Paragraph l(d) of this Article shall apply.

 

2.                                       Responsibility of BUILDER:

 

The BUILDER shall be responsible for storing and handling with
reasonable care of the BUYER’s Supplies after delivery thereof at the Shipyard,
and shall, at its own cost and expense, install them in or on the VESSEL, unless
otherwise provided herein or agreed by the parties hereto, provided, always,
that the BUILDER shall not be responsible for quality, efficiency and/or
performance of any of the BUYER’s Supplies.

 

(End of Article)

 

XVI-2

 

ARTICLE XVII - INSURANCE

 

1.                                       Extent of Insurance Coverage

 

From the time of launching until delivery of the VESSEL, The BUILDER
shall, at its own cost and expense, insure the VESSEL and all machinery and
equipment, appurtenances and outfits, including the BUYER’S Supplies, built
into or installed in or upon the VESSEL, against all risks under the “Institute
Causes for BUILDER’s Risk”, with first class insurance company or
underwriters in Korea on terms corresponding to “Institute Clause of London
Underwriters for Builder’s Risks”. The amount of such insurance coverage shall,
up to the date of delivery of the VESSEL, not be less than the Contract Price
plus the value of the BUYER’s Supplies in the custody of the Shipyard.

 

2.                                       Application of the Recovered Amounts

 

In the event that the VESSEL shall be damaged from any insured cause at
any time before delivery of the VESSEL, and in the further event that such
damage shall not constitute an actual or constructive total loss of the VESSEL,
the amount received in respect of the insurance shall be applied by the BUILDER
in repair of such damage, satisfactory to the Classification Society, and the
BUYER shall accept the VESSEL under this Contract if completed in accordance
with this Contract and the Specifications, however, subject to the extension of
delivery time under Article VIII hereof (except in case of negligence of
the BUILDER)

 

Should the VESSEL from any cause become an actual or constructive total
loss, the BUILDER shall either:

 

(a)                                  proceed in accordance with the terms of this
Contract, in which case the amount received in respect of the insurance shall
be applied to the construction and repair of damage of the VESSEL, provided the
parties hereto shall have first agreed thereto in writing and to such
reasonable extension of delivery time as may be necessary for the
completion of such reconstruction and repair; or

 

XVII-1

 

(b)                                 refund promptly to the BUYER the full amount
of all sums paid by the BUYER to the BUILDER as installments in advance of
delivery of the VESSEL without any interest, and deliver to the BUYER all BUYER’S
Supplies (or the insurance proceeds paid with respect thereto), in which case
this Contract shall be deemed to be automatically terminated and all right,
duties, liabilities and obligations of each of the parties to the other shall
forthwith cease and terminate.

 

In the event that no agreement on the above (a) is reached within
Two (2) months, then above (b) shall apply.

 

3.                                       Termination of Builder’s Obligation to Insure

 

The BUILDER shall be under no obligation to insure the VESSEL hereunder
after delivery of the VESSEL.

 

(End of Article)

 

XVII-2

 

ARTICLE XVIII - NOTICE 

 

1.                                       Address:

 

Any and all notices and communications in connection with this Contract
shall be addressed as follows:

 

To the BUYER:

 

Stolt-Nielsen Transportation Group B.V.

Westerlaan 5

3016 GK Rotterdam

Harbour 190

The Netherlands

 

Telefax No. : + 31 10 264 4404 

Telephone No.:+ 31 10 299 6666

Email: shina-projects@sntg.com

Contact: Mr. Jens Lassen

 

To the BUILDER:

 

ShinA Shipbuilding Co., Ltd.

227, Donam-Dong, Tongyeong, Gyeongnam, Korea

Telefax No. :+82-55-649-2114

Telephone No. :+82-55-640-3300/3301

Email: sales@shinaship.co.kr

Contact: Mr. S.P. Lee

 

2.                                       Language:

 

Any and all notices and communications in connection with this Contract
shall be written in the English language.

 

XVIII-1

 

3.                                       Effective Date of Notice:

 

The notice in connection with this Contract shall become effective from
the date when such notice is received by the BUYER or by the BUILDER except
otherwise described in the Contract,

 

(End of Article)

 

XVIII-2

 

ARTICLE XIX - EFFECTIVE DATE OF CONTRACT

 

This Contract shall become effective upon signing by the parties
hereto.

 

(End of Article)

 

XIX-1

 

ARTICLE XX
-
INTERPRETATION

 

1.                                       Laws Applicable:

 

The parties hereto agree that the validity and interpretation of this
Contract and of each Article and part thereof shall be governed by
the laws of England.

 

2.                                       Discrepancies:

 

All general language or requirements embodied in the Specifications are
intended to amplify, explain and implement the requirements of this Contract.
However, in the event that any language or requirements so embodied permit of
an interpretation inconsistent with any provisions of this Contract, then, in
each and every such event, the applicable provisions of this Contract shall
prevail and govern. In the event of conflict between the Specifications and
Plans, the Specifications shall prevail and govern.

 

3.                                       Entire Agreement:

 

This Contract contains the entire agreement and understanding between
the parties hereto and supersedes all prior negotiations, representations,
undertaking and agreements on any subject matter of this Contract.

 

4.                                       Amendments and Supplements:

 

Any supplement, memorandum of understanding or amendment, whatsoever form it
may be relating to this Contract, to be made and signed among parties
hereof after signing this Contract, shall become an integral part of this
Contract and shall be predominant over the respective corresponding Article and/or
Paragraph of this Contract.

 

(End of Article)

 

XX-1

 

IN WITNESS WHEREOF, the parties hereto have caused this Contract to be
duly executed on the day and year first above written.

 

 

	
  BUYER:

  	
   

  	
  BUILDER:

  
	
  For
  and on behalf of

  	
   

  	
  For
  and on behalf of

  
	
  Stolt-Nielsen
  Transportation Group B.V.

  	
   

  	
  ShinA
  Shipbuilding Co., Ltd

  

 

	
  /s/
  Otto Fritzner

  	
   

  	
  /s/
  Su-Ean Yoo

  
	
  By:

  	
  Mr. Otto
  Fritzner

  	
   

  	
  By:
  

  	
  Su-Ean
  Yoo

  
	
  Title:

  	
  C.E.O

  	
  Title:

  	
  President &
  C.E.O

  
					

 

	
  WITNESS:

  	
   

  
	
  For
  and on behalf of 

  	
   

  
	
  Barry
  Rogliano Salles

  	
   

  

 

	
  /s/
  Francois Cadiou

  	
   

  	
   

  
	
  By:

  	
  Mr. Francois
  Cadiou

  	
   

  	
   

  	
   

  
	
  Title:

  	
  Partner

  	
   

  	
   

  
					

 

E - 1

 

EXHIBIT “A”

 

LETTER
OF REFUNDMENT GUARANTEE NO.

 

Gentlemen
:

 

We
hereby open our irrevocable letter of guarantee No.            in
favour of                                (hereinafter
called the “BUYER”) for account of Shina Shipbuilding Co., Ltd. (hereinafter
called the “BUILDER”) as follows in consideration of the BUYER entering into
the shipbuilding contract dated
                 (hereinafter
called the “Contract”) made by and among the BUYER and the BUILDER for the
construction of one(l) single screw diesel driven DWT 44,000 IMO II/III Product
/ Chemical Tanker having BUILDER’S Hull No. S         (hereinafter
called the “VESSEL”) and of making arrangements to pay the first installment.

 

If
in connection with the terms of the Contract the BUYER shall become entitled to
a refund of the advance payment made to the BUILDER prior to the delivery of
the VESSEL, we hereby irrevocably guarantee the repayment of the same to the
BUYER immediately on demand, US$ [amount of the First Installment], together with interest thereon at
the rate of Seven per cent (7%) per annum from the date following the date of
receipt by the BUILDER to the date of remittance by telegraphic transfer of
such refund.

 

The
amount of this guarantee will be automatically increased, not more than Two (2) times,
upon BUILDER’S receipt of the subsequent installments: each time by the amount
of installment of USD [amount of the Second Installment] USD [amount of the Third Installment], respectively plus interest thereon
as provided in the Contract., but in any eventuality the amount of this
guarantee shall not exceed the total sum of US$              [amount
of all the pre-delivery Installments] (Say U.S. Dollars                   only)
plus interest thereon at the rate of Seven per cent (7%) per annum from the
date following the date of BUILDER’S receipt of each installment to the date of
remittance by telegraphic transfer of the refund.

 

A-1

 

In
case any refund is made to you by the BUILDER or by us under this guarantee,
our liability hereunder shall be automatically reduced by the amount of such
refund.

 

The
BUYER may assign its rights under the letter of guarantee on the same
terms and to the same person to which it is permitted to assign its rights
under the Contract.

 

In
the event of cancellation of the Contract being based on delays due to force
majeure, no interest shall be paid as required by Article X of the
Contract.

 

This
letter of guarantee is available against BUYER’S simple receipt and signed
statement certifying that BUYER’S demand for refund has been made in conformity
with Article X of the Contract and the BUILDER has failed to make the
refund within Thirty (30) days after your demand. Refund shall be made to you
by telegraphic transfer in United States Dollars.

 

This
letter of guarantee shall expire and become null and void upon receipt by the
BUYER of the sum guaranteed hereby or upon acceptance by the BUYER of the
delivery of the VESSEL in accordance with the terms of the Contract and, in
either case, this letter of guarantee shall be returned to us. This guarantee
is valid from the date of this letter of guarantee until such time as the
VESSEL is delivered by the BUILDER to the BUYER in accordance with the terms of
the Contract.

 

Notwithstanding
the provisions hereinabove, in case we receive notification from you or the
BUILDER confirmed by an Arbitrator stating that your claim to cancel the
Contract or. your claim for refundment thereunder has been disputed and
referred to Arbitration in accordance with the provisions of the Contract, the
period of validity of this guarantee shall be extended until Thirty (30) days
after the final award shall be published in the Arbitration in favour of the
BUYER. In such case, this guarantee shall not be available unless and until
such acknowledged copy of the final award in the Arbitration justifying your
claim is presented to us.

 

A-2

 

Notice
of claim hereunder may be made the service on our office [details]

 

This
guarantee shall be governed by the Laws of England.

 

Very
truly yours,

 

A-3

 

EXHIBIT “B”

 

Shina Shipbuilding Co., Ltd.

227, Donam-dong, Tongyeong,

Gyeongnam, Korea 650-150

 

Date:                  ,
200

 

PERFORMANCE GUARANTEE

 

In
consideration of the assignment of the shipbuilding contract dated (hereinafter
called the “Contract”) by us to                having
your Hull No. S                        (hereinafter
called the “VESSEL”) which provides among other things for payment of the
Contract Price amounting to                  United
States Dollars
(US$              )
(subject to adjustment as per the terms of the Contract);

 

We,
the undersigned, hereby irrevocably and unconditionally guarantee to you, your
successors, and assigns the due and faithful performance by the BUYER of its
all liabilities and responsibilities under the Contract and any supplement,
amendment, change or modification hereafter made thereto, including but not
limited to, due and prompt payment of the Contract Price by the BUYER to you,
your successors, and assigns under the Contract and any supplement, amendment,
change or modification as aforesaid (hereby expressly waiving notice of any
such supplement, amendment, change or modification as may be agreed to by
the BUYER and confirming that this guarantee shall be fully applicable to the
Contract as so supplemented, amended, changed or modified).

 

This
Performance Guarantee shall be governed by the laws of England.

 

GUARANTOR:

BY:

TITLE:

WITNESS:

 

B-1EXHIBIT 10.6

 

MICROCHIP TECHNOLOGY
INCORPORATED

 

2004 EQUITY INCENTIVE PLAN

 

NOTICE OF GRANT OF
RESTRICTED STOCK UNITS

 

Unless otherwise defined
herein, the terms used in this Notice of Grant of Restricted Stock Units (“Grant
Notice”) shall have the same meanings as those defined in the 2004 Equity
Incentive Plan (the “Plan”).

 

	
  Grantee:

  	
   

  	
   

  	
   

  

 

 

You have been granted an
Award of Restricted Stock Units (“RSU/s”) subject to and in accordance with the
express terms and conditions of the Plan and the Restricted Stock Unit
Agreement attached hereto as Exhibit A (“Agreement”). Each such RSU is
equivalent to the right to receive one share of Common Stock of the Company (“Share”)
for purposes of determining the number of Shares subject to this Award. No
Shares will be issued until the vesting conditions of the Award described below
are satisfied and the restrictions lapse. This Award does not entitle Grantee
to any stockholder rights with respect to the underlying Shares until the
vesting conditions of the Award described below are satisfied and the
restrictions lapse. Additional terms of this Award are as follows:

 

	
  Grant
  Number:

  	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
   

  
	
  Grant
  Date:

  	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
   

  
	
  Vest
  Begin Date:

  	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
   

  
	
  Vesting
  Period:

  	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
   

  
	
  Purchase
  Price Per RSU:

  	
   

  	
  $0.00
  (USD)

  	
   

  
	
   

  	
   

  	
   

  	
   

  
	
  Total
  Number of RSUs Granted:

  	
   

  	
   

  	
   

  

 

Vesting
Schedule. The RSUs vest and all restrictions lapse «vest_schedule»  All vesting is contingent upon the Grantee’s
continual status as a Service Provider measured from the Grant Date through the
applicable Vest Date.

 

Termination
Period. This Award automatically terminates and Grantee’s
rights are forfeited with respect to any portion of the RSUs unvested on the
date Grantee ceases to be a Service Provider. In no event shall this Award vest
later than the Vesting Schedule outlined above.

 

Choice of
Languages For Employees of Canadian Locations Only. The
undersigned agrees that it is his or her express wish that this form and
all documents relating to his participation in the scheme be drawn in the
English language only. Le soussigné convient que sa volonté expresse est que ce
formulaire ainsi que tous les documents se rapportant à sa participation au
régime soient rédigés en langue anglaise seulement.

 

Binding
Agreements. By signature of Grantee and Company’s
representative below, the parties agree that this Grant Notice, the Agreement,
and the Plan constitute Grantee’s entire agreement with respect to this Award
and agree to be bound by the terms therein. Grantee hereby agrees to accept as
binding, conclusive and final all decisions or interpretations of the
Administrator upon any questions relating to the Plan, the Agreement, and/or
this Award. This Award may be modified by the Company, but  in accordance with Section 21(c) of
the Plan, it may not be modified adversely to Grantee’s interest except by
means of a writing signed by the Company and Grantee. The Company will
administer the Plan from the United States of America. The internal laws of the
State of Arizona, United States of America, but not its choice of law
principles, will govern this Award.

 

	
  GRANTEE

  	
  MICROCHIP
  TECHNOLOGY INCORPORATED

  
	
   

  	
   

  
	
  Signature:

  	
   

  	
   

  	
  By:

  	
  

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  
	
  Address:

  	
   

  	
   

  	
   

  	
  Steve Sanghi, President and CEO

  
	
   

  	
   

  	
   

  	
   

  
	
  Dated:

  	
   

  	
   

  	
   

  
									

 

 

EXHIBIT A

 

MICROCHIP TECHNOLOGY
INCORPORATED

 

2004 EQUITY INCENTIVE PLAN

 

RESTRICTED STOCK UNIT AGREEMENT

 

1.                                       Grant of Restricted Stock Units. The Company hereby grants to the Grantee
named in the Notice of Grant of Restricted Stock Units (“Grant Notice”) an
Award of Restricted Stock Units (“RSU/s”), as set forth in the Grant Notice and
subject to the terms and conditions in this Restricted Stock Unit Agreement (“Agreement”)
and the Company’s 2004 Equity Incentive Plan (the “Plan”). Unless otherwise
defined herein, the terms defined in the Plan shall have the same defined
meanings in this Agreement.

 

2.                                       Company’s Obligation. Each RSU represents the right to receive a
Share in accordance with the Vesting Period in the Grant Notice. Unless and
until the RSUs vest, the Grantee will have no right to receive Shares
underlying such RSUs. Prior to actual distribution of Shares pursuant to any
vested RSUs, such RSUs will represent an unsecured obligation of the Company,
payable (if at all) only from the general assets of the Company.

 

3.                                       Vesting Schedule. Subject to paragraph 4 of this Agreement,
the RSUs awarded by this Agreement will vest and all restrictions lapse
according to the vesting schedule specified in the Grant Notice.

 

4.                                       Forfeiture upon Termination as a Service
Provider. Notwithstanding
any contrary provision of this Agreement or the Grant Notice, if the Grantee
terminates service as a Service Provider for any or no reason prior to vesting,
the unvested RSUs awarded by this Agreement will thereupon be forfeited at no
cost to the Company.

 

5.                                       Payment after Vesting. Any RSUs that vest in accordance with paragraph
3 of this Agreement will be paid to the Grantee (or in the event of the Grantee’s
death, to his or her estate) in Shares, upon satisfaction, as determined by the
Company, of any required tax or other withholding as set forth in Section 9
of this Agreement. The Shares will be issued to the Grantee as soon as
practicable after the vesting date, but in any event, within the period ending
on the later to occur of the date that is two and a half (2 1⁄2) months from the
end of (i) the Grantee’s tax year that includes the applicable vesting
date, or (ii) the Company’s tax year that includes the applicable vesting
date.

 

6.                                       Payments after Death. Any distribution or delivery to be made to
the Grantee under this Agreement will, if the Grantee is then deceased, be made
to the administrator or executor of the Grantee’s estate. Any such
administrator or executor must furnish the Company with (a) written notice
of his or her status as transferee, and (b) evidence satisfactory to the
Company to establish the validity of the transfer and compliance with any laws
or regulations pertaining to said transfer.

 

7.                                       Grant is Not Transferable. Except to the limited extent provided in
paragraph 6 of this Agreement, this grant and the rights and privileges
conferred hereby will not be transferred, assigned, pledged or hypothecated in
any way (whether by operation of law or otherwise) and will not be subject to
sale under execution, attachment or similar process. Upon any attempt to
transfer, assign, pledge, hypothecate or otherwise dispose of this grant, or
any right or privilege conferred hereby, or upon any attempted sale under any
execution, attachment or similar process, this grant and the rights and
privileges conferred hereby immediately will become null and void.

 

 

8.                                       Rights as Stockholder. Neither the Grantee nor any person claiming
under or through the Grantee will have any of the rights or privileges of a
stockholder of the Company in respect of any Shares deliverable hereunder
unless and until certificates representing such Shares will have been issued,
recorded on the records of the Company or its transfer agents or registrars,
and delivered to the Grantee or Grantee’s broker or had the Shares
electronically transferred to Grantee’s account.

 

9.                                       Tax Obligations. Grantee agrees to make appropriate
arrangements with the Company (or the Parent or Subsidiary employing or
retaining Grantee) in accordance with the procedures offered by the Company for
the satisfaction of all Federal, state, local and foreign income and employment
tax withholding requirements applicable to the issuance of Shares pursuant to
an RSU Award. The Administrator may in its sole discretion determine
whether the minimum required withholding taxes with respect to such RSUs will
be paid by selling a portion of vested shares or by direct payment from the
Grantee to the Company, by some other method, or by some combination thereof.

 

The Grantee grants to the
Company the irrevocable authority, as agent of Grantee and on his behalf, to
sell or procure the sale of sufficient Shares subject to this Award so that the
net proceeds receivable by the Company are as far as possible equal to but not
less than the amount of any tax the Grantee is liable for and the Company shall
account to Grantee for any balance.

 

Grantee
acknowledges and agrees that the Company may refuse to deliver Shares if
Grantee has not made appropriate arrangements with the Company to satisfy the
minimum tax withholding requirements.

 

10.                                 Acknowledgments.
The Grantee expressly acknowledges the following:

 

(a)   The Company (whether or not Grantee’s
employer) is granting the Award. That the grant of the Award, future grants of
Awards, and benefits and rights provided under the Plan are at the complete
discretion of the Company and do not constitute regular or periodic payments. No
grant of Awards will be deemed to create any obligation to grant any further
Awards, whether or not such a reservation is explicitly stated at the time of
such a grant. The benefits and rights provided under the Plan are not to be
considered part of Grantee’s salary or compensation for purposes of
calculating any severance, resignation, redundancy or other end of service
payments, vacation, bonuses, long-term service awards, indemnification, pension
or retirement benefits, or any other payments, benefits or rights of any kind. Grantee
waives any and all rights to compensation or damages as a result of the
termination of employment with the Company or its subsidiaries for any reason
whatsoever insofar as those rights result or may result from:

 

(i)                                     the loss or diminution in value of such
rights under the Plan, or

 

(ii)                                  Grantee ceasing to have any rights under, or
ceasing to be entitled to any rights under the Plan as a result of such
termination.

 

(b)   The Company has the right, at any time to amend, suspend or terminate
the Plan. The Plan will not be deemed to constitute, and will not be construed
by Grantee to constitute, part of the terms and conditions of employment,
and that the Company will not incur any liability of any kind to Grantee as a
result of any change or amendment, or any cancellation, of the Plan at any
time.

 

(c)   The Grantee’s employment with the Company and
its Subsidiaries is not affected at all by any Award and it is agreed by the
Grantee not to create an entitlement. Accordingly, the terms of the Grantee’s
employment with the Company and its Subsidiaries will be determined from time
to time by the Company or the Subsidiary employing the Grantee (as the case may be),
and the Company or the Subsidiary will have the right, which is hereby
expressly reserved, to terminate or change the terms of the employment of the
Grantee at any time for any reason whatsoever, with or without good cause or

 

2

 

notice, except as may be
expressly prohibited by the laws of the jurisdiction in which the Grantee is
employed.

 

(d)   By entering into this Agreement, and as a
condition of the grant of the Award, Grantee consents to the collection, use,
and transfer of personal data as described in this subsection to the full
extent permitted by and in full compliance with Applicable Law.

 

(i)                                     Grantee understands that the Company and its
Subsidiaries hold certain personal information about the Grantee, including,
but not limited to, name, home address and telephone number, date of birth,
social insurance number, salary, nationality, job title, any Shares or
directorships held in the Company, details of all Awards or other entitlement
to Shares awarded, canceled, exercised, vested, unvested, or outstanding in
Grantee’s favor, for the purpose of managing and administering the Plan (“Data”).

 

(ii)                                  Grantee further understands that the Company
and/or its Subsidiaries will transfer Data among themselves as necessary for
the purposes of implementation, administration, and management of Grantee’s
participation in the Plan, and that the Company and/or its Subsidiary may each
further transfer Data to any third parties assisting the Company in the
implementation, administration, and management of the Plan (“Data Recipients”).

 

(iii)                               Grantee understands that these Data
Recipients may be located in Grantee’s country of residence or elsewhere,
such as the United States. Grantee authorizes the Data Recipients to receive,
possess, use, retain, and transfer Data in electronic or other form, for the
purposes of implementing, administering, and managing Grantee’s participation
in the Plan, including any transfer of such Data, as may be required for
Plan administration and/or the subsequent holding of Shares on Grantee’s
behalf, to a broker or third party with whom the Shares acquired on exercise may be
deposited.

 

(iv)                              Grantee understands that Grantee may, at any
time, review the Data, request that any necessary amendments be made to it, or
withdraw Grantee’s consent herein in writing by contacting the Company. Grantee
further understands that withdrawing consent may affect Grantee’s ability
to participate in the Plan.

 

(e)   Choice of Language.

 

(i)                                     For Employees of Canadian Locations:  The undersigned agrees that it is his or her
express wish that this form and all documents relating to his
participation in the scheme be drawn in the English language only. Le soussigné
convient que sa volonté expresse est que ce formulaire ainsi que tous les
documents se rapportant à sa participation au régime soient rédigés en langue
anglaise seulement.

 

(ii)                                  For Employees of Locations Other than
Canada:  Grantee has received this
Agreement and any other related communications and consents to having received
these documents solely in English.

 

11.                                 Binding Agreement. Subject to the limitation on the
transferability of this grant contained herein, this Agreement will be binding
upon and inure to the benefit of the heirs, legatees, legal representatives,
successors and assigns of the parties hereto.

 

12.                                 Additional Conditions to Issuance of Stock. If at any time the Company will determine,
in its discretion, that the listing, registration or qualification of the
Shares upon any securities exchange or under any state or federal law, or the
consent or approval of any governmental regulatory authority is necessary or
desirable as a condition to the issuance of Shares to the Grantee (or his or
her estate), such issuance will not occur unless and

 

3

 

until
such listing, registration, qualification, consent or approval will have been
effected or obtained free of any conditions not acceptable to the Company. The
Company will make all reasonable efforts to meet the requirements of any such
state or federal law or securities exchange and to obtain any such consent or
approval of any such governmental authority.

 

13.                                 Administrator Authority. The Administrator has the power to
interpret the Plan, the Grant Notice and this Agreement and to adopt such rules for
the administration, interpretation and application thereof as are consistent
therewith and to interpret or revoke any such rules (including, but not
limited to, the determination of whether or not any RSUs have vested). All
actions taken and all interpretations and determinations made by the
Administrator in good faith will be final and binding upon Grantee, the Company
and all other interested persons. No member of the Administrator will be
personally liable for any action, determination or interpretation made in good
faith with respect to the Plan, the Grant Notice or this Agreement.

 

14.                                 Notice Requirement. Where there is a legal requirement for any
notice or document to be sent to any person by any other person, it shall be
considered sent if an electronic transmission of the relevant information is
sent in a form previously determined as being acceptable to the
Administrator. For the avoidance of doubt, the Administrator may dispense
with the requirement to tender a certificate on the issuance of Shares under an
RSU Award where the Administrator authorizes any system permitting electronic
notification.

 

15.                                 Address for Notices. Any notice to be given to the Company under
the terms of this Agreement will be addressed to the Company at 2355 West
Chandler Boulevard, Chandler AZ 85224, Attn: Stock Administration, or at
such other address as the Company may hereafter designate in writing or
electronically.

 

16.                                 Entire Agreement; Governing Law. The Plan and Grant Notice are incorporated
herein by reference. The Plan, Grant Notice and this Agreement constitute the
entire agreement of the parties with respect to the subject matter hereof and
supersede in their entirety all prior undertakings and agreements of the
Company and Grantee with respect to the subject matter hereof, and may not
be modified adversely to the Grantee’s interest except by means of a writing
signed by the Company and Grantee. The Company will administer the Plan from
the United States of America. This Agreement, the Grant Notice and all Awards
are governed by the internal substantive laws, but not the choice of law
principles, of the State of Arizona, United States of America.

 

4

 

By
Grantee’s signature, Grantee agrees that this Award is granted under and
governed by the terms and conditions of the Plan, the Grant Notice and this
Agreement. Grantee has reviewed the Plan, the Grant Notice and this Agreement
in their entirety, has had an opportunity to obtain the advice of counsel prior
to executing this Agreement and fully understands all provisions of the Plan,
the Grant Notice and this Agreement. Grantee hereby agrees to accept as
binding, conclusive and final all decisions or interpretations of the
Administrator upon any questions relating to the Plan, the Grant Notice and
this Agreement.

 

	
  GRANTEE

  	
  MICROCHIP TECHNOLOGY INCORPORATED

  
	
   

  	
   

  
	
   

  	
   

  
	
   

  	
   

  	
  By

  	
  

  	
   

  
	
  Signature

  	
   

  	
   

  	
  Steve Sanghi, President
  and CEO

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  Print Name

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  Date

  	
   

  	
   

  

 

5

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00104-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00104-of-00352.parquet"}]]