Document:

EXHIBIT 10.54

 

Office Lease

 

LARKSPUR LANDING OFFICE PARK

LARKSPUR LANDING BUILDING 1100

LARKSPUR, CALIFORNIA

 

Between

 

CA-LARKSPUR LANDING OFFICE PARK LIMITED PARTNERSHIP, a Delaware limited partnership

 

as Landlord,

 

and

 

DIGITAL DOMAIN PRODUCTIONS, INC., a Delaware corporation

 

as Tenant

  

  

  

OFFICE LEASE

 

This Office Lease (this “Lease”), dated as of the date set forth in Section 1.1, is made by and between CA-LARKSPUR LANDING OFFICE PARK LIMITED PARTNERSHIP, a Delaware limited partnership (“Landlord”), and DIGITAL DOMAIN PRODUCTIONS, INC., a Delaware corporation (“Tenant”).  The following exhibits are incorporated herein and made a part hereof:  Exhibit A (Outline of Premises); Exhibit B-1 (Suite 255 and Suite 270 Work Letter); Exhibit B-2 (Suite 350 Work Letter); Exhibit C (Form of Confirmation Letter); Exhibit D (Rules and Regulations); Exhibit E (Judicial Reference); Exhibit F (Additional Provisions); Exhibit G (Asbestos Notification); and Exhibit H (Guaranty of Lease).

 

	
1

	
BASIC LEASE INFORMATION

 

	
1.1

	
Date:

	  	
August 2, 2011

	  	  	  	  	  
	
1.2

	
Premises.

	  	  
	  	  	  	  	  
	  	
1.2.1

	
“Building”:

	  	
1100 Larkspur Landing Circle, Larkspur, California, commonly known as Larkspur Landing Building 1100.

	  	  	  	  	  
	  	
1.2.2

	
“Premises”:

	  	
14,212 rentable square feet of space located on the second and third floors of the Building and commonly known as Suite 255 (“Suite 255”) consisting of approximately 7,560 rentable square feet; Suite 270 (“Suite 270”) consisting of approximately 1,949 rentable square feet and Suite 350 (“Suite 350”) consisting of approximately 4,703 rentable square feet, the outline and location of which is set forth in Exhibit A.  If the Premises includes any floor in its entirety, all corridors and restroom facilities located on such floor shall be considered part of the Premises.

	  	  	  	  	  
	  	
1.2.3

	
“Property”:

	  	
The Building, the parcel(s) of land upon which it is located, and, at Landlord’s discretion, any parking facilities and other improvements serving the Building and the parcel(s) of land upon which such parking facilities and other improvements are located.

	  	  	  	  	  
	  	
1.2.4

	
“Project”:

	  	
The Property or, at Landlord’s discretion, any project containing the Property and any other land, buildings or other improvements.

	  	  	  	  	  
	
1.3

	
Term

	  	  
	  	  	  	  	  
	  	
1.3.1

	
Term:

	  	
The term of this Lease (the “Term”) shall commence on the Commencement Date (defined below) and end on the Expiration Date (or any earlier date on which this Lease is terminated as provided herein).  The “Commencement Date” shall mean, as applicable, (1) for Suite 255 and Suite 270, the Suite 255 and Suite 270 Commencement Date (defined below) and (2) for Suite 350, the Suite 350 Commencement Date (defined below).

	  	  	  	  	  
	  	
1.3.2

	
Commencement Date:

	  	  
	  	  	  	  	  
	  	  	
A. “Suite 255 and Suite 270 Commencement Date”:

	  	
The earlier of (i) the date on which Suite 255 and Suite 270 are Ready for Occupancy (defined in Exhibit B-1), and (ii) November 1, 2011; provided, however, that in no event shall the Suite 255 and Suite 270 Commencement Date occur prior to November 1, 2011.

	  	  	  	  	  
	  	  	
B. “Suite 350 Commencement Date”:

	  	
December 1, 2011.

 

  

1

  

 

	  	
1.3.3

	
“Expiration Date”:

	  	
November 30, 2014.

	  	  	  	  	  
	
1.4

	
Base Rent.

	  	  
	 	 	 	 	 
	  	
1.4.1

	
“Suite 255 and Suite 270 Base Rent”:

	  	  

 

	
Period During

Term

	 	
Annual Suite 255

and Suite 270 Base

Rent Per Rentable

Square Foot

	 	 	
Monthly Suite

255 and Suite

270 Base Rent

Per Rentable

Square Foot

(rounded to the

nearest 100th of

a dollar)

	 	 	
Monthly

Installment

of Suite 255 and

Suite 270 Base

Rent

	 
	  	 	 	 	 	 	 	 	 	 
	
Suite 255 and Suite 270 Commencement Date through November 30, 2012

	 	$	33.00	 	 	$	2.75	 	 	$	26,149.75	 
	  	 	 	 	 	 	 	 	 	 	 	 	 
	
December 1, 2012 through November 30, 2013

	 	$	33.99	 	 	$	2.83	 	 	$	26,934.24	 
	  	 	 	 	 	 	 	 	 	 	 	 	 
	
December 1, 2013 through November 30, 2014

	 	$	35.01	 	 	$	2.92	 	 	$	27,742.51	 

 

	 	1.4.2 	“Suite 350 Base Rent”: 	 	 

 

	
Period During

Term

	 	
Annual Suite 350

Base Rent Per

Rentable Square

Foot

	 	 	
Monthly Suite

350 Base Rent

Per Rentable

Square Foot

(rounded to the

nearest 100th of

a dollar)

	 	 	
Monthly

Installment

of Suite 350 Base

Rent

	 
	  	 	 	 	 	 	 	 	 	 
	
Suite 350 Commencement Date through November 30, 2012

	 	$	33.00	 	 	$	2.75	 	 	$	12,933.25	 
	  	 	 	 	 	 	 	 	 	 	 	 	 
	
December 1, 2012 through November 30, 2013

	 	$	33.99	 	 	$	2.83	 	 	$	13,321.25	 
	  	 	 	 	 	 	 	 	 	 	 	 	 
	
December 1, 2012 through November 30, 2014

	 	$	35.01	 	 	$	2.92	 	 	$	13,721.00	 

 

As used herein, the term “Base Rent” shall mean, as applicable, the Suite 255 and 270 Base Rent and the Suite 350 Base Rent.

 

	
1.5

	
“Base Year” for Expenses:

	
Calendar year 2012.

	  	  	  
	  	
“Base Year” for Taxes:

	
Calendar year 2012.

 

  

2

  

 

	
1.6

	
“Tenant’s Share”:

	
With respect to Suite 255 and Suite 270, Tenant’s Share shall be 11.5673% (based upon a total of 82,206 rentable square feet in the Building).

	 	 	 
	  	  	
With respect to Suite 350, Tenant’s Share shall be 5.7210% (based upon a total of 82,206 rentable square feet in the Building).

	 	 	 
	  	  	
After both (1) the Suite 255 and Suite 270 Commencement Date has occurred and (2) the Suite 350 Commencement Date has occurred, Tenant’s Share for the Premises shall be 17.2883% (based upon a total of 82,206 rentable square feet in the Building).

	 	 	 
	
1.7

	
“Permitted Use”:

	
General office use consistent with a first-class office building; provided that in no event shall the Premises, or any portion of the Premises, be used for the operation of (a) an executive suite business, or (b) a retail secretarial services business.

	 	 	 
	
1.8.

	
“Security Deposit”:

	
$42,000.00, as more particularly described in Section 21.

	 	 	 
	  	
Prepaid Base Rent:

	
$39,083.00, as more particularly described in Section 3.

	 	 	 
	
1.9

	
Parking:

	
With respect to Suite 255 and 270, Tenant shall be entitled to thirty-one (31) unreserved parking spaces, at the rate of $0 per space per month.

	 	 	 
	  	  	
With respect to Suite 350, Tenant shall be entitled to sixteen (16) unreserved parking spaces, at the rate of $0 per space per month.

	 	 	 
	
1.10

	
Address of Tenant:

	
Before the Commencement Date:

	 	 	 
	  	  	
300 Rose Avenue

	  	  	
Venice, California 90291

	 	 	 
	  	  	
From and after the Commencement Date:  the Premises.

	 	 	 
	
1.11

	
Address of Landlord:

	
c/o Equity Office

	  	  	
700 Larkspur Landing Circle, Suite 280

	  	  	
Larkspur, California  94939

	  	  	
Attention: Building manager

	  	  	  
	  	  	
with copies to:

	  	  	  
	  	  	
Equity Office

	  	  	
2655 Campus Drive

	  	  	
Suite 100

	  	  	
San Mateo, California  94403

	  	  	
Attn:  Managing Counsel

	  	  	  
	  	  	
and

	  	  	  
	  	  	
Equity Office

	  	  	
Two North Riverside Plaza

	  	  	
Suite 2100

	  	  	
Chicago, IL  60606

	  	  	
Attn:  Lease Administration

	 	 	 
	
1.12

	
Broker(s):

	
BASE Partners (“Tenant’s Broker”), representing Tenant, and Cassidy Turley/BT Commercial (“Landlord’s Broker”), representing Landlord.

 

  

3

  

 

	
1.13

	
Building HVAC Hours and Holidays:

	
“Building HVAC Hours” mean 7:00 a.m. to 6:00 p.m., Monday through Friday, excluding the day of observation of New Year’s Day, Presidents Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Christmas Day, and, at Landlord’s discretion, any other locally or nationally recognized holiday that is observed by other buildings comparable to and in the vicinity of the Building (collectively, “Holidays”).

	  	  	  
	
1.14

	
“Transfer Radius”:

	
The area within one (1) mile of the Building.

	  	  	  
	
1.15

	
“Tenant Improvements”:

	
As defined in Exhibit B-1 and Exhibit B-2, respectively.

	  	  	  
	
1.16

	
“Guarantor”:

	
Digital Domain Media Group, Inc., a Florida corporation.  Concurrently with Tenant’s execution and delivery hereof, Tenant shall cause Guarantor to execute and deliver a guaranty in favor of Landlord in the form of Exhibit H.

 

	
2

	
PREMISES AND COMMON AREAS.

 

	 	
2.1 

	
The Premises.

 

2.1.1        Subject to the terms hereof, Landlord hereby leases the Premises to Tenant and Tenant hereby leases the Premises from Landlord. Landlord and Tenant acknowledge that the rentable square footage of the Premises is as set forth in Section 1.2.2 and the rentable square footage of the Building is as set forth in Section 1.6. With respect to Suite 255 and Suite 270 only, at any time Landlord may deliver to Tenant a notice substantially in the form of Exhibit C, as a confirmation of the information set forth therein. Tenant shall execute and return (or, by notice to Landlord, reasonably object to) such notice within ten (10) days after receiving it, and if Tenant fails to do so, Tenant shall be deemed to have executed and returned it without exception.

 

2.1.2        Except as expressly provided herein, the Premises is accepted by Tenant in its condition and configuration existing on the date hereof (or in such other condition and configuration as any existing tenant of the Premises may cause to exist in accordance with its lease), without any obligation of Landlord to perform or pay for any alterations to the Premises, and without any representation or warranty regarding the condition of the Premises, the Building or the Project or their suitability for Tenant’s business. The foregoing provisions of this Section 2 shall not abrogate Landlord’s obligations and the Tenant’s rights under Section 5, Section 6.3 and Section 7.1 of this Lease nor pursuant to Exhibits B-1 and B-2 hereto.

 

2.2      Common Areas. Tenant may use, in common with Landlord and other parties and subject to the Rules and Regulations (defined in Exhibit D), any portions of the Property that are designated from time to time by Landlord for such use (the “Common Areas”).

 

3         RENT. Tenant shall pay all Base Rent and Additional Rent (defined below) (collectively, “Rent”) to Landlord or Landlord’s agent, without prior notice or demand or any setoff or deduction, at the place Landlord may designate from time to time. As used herein, “Additional Rent” means all amounts, other than Base Rent, that Tenant is required to pay Landlord hereunder. Monthly payments of Base Rent and monthly payments of Additional Rent for Expenses (defined in Section 4.2.2), Taxes (defined in Section 4.2.3) and parking (collectively, “Monthly Rent”) shall be paid in advance on or before the first day of each calendar month during the Term; provided, however, that the installment of Base Rent for the first full calendar month for which Base Rent is payable hereunder shall be paid upon Tenant’s execution and delivery hereof. Except as otherwise provided herein, all other items of Additional Rent shall be paid within 30 days after Landlord’s request for payment. Rent for any partial calendar month shall be prorated based on the actual number of days in such month. Without limiting Landlord’s other rights or remedies, (a) if any installment of Rent is not received by Landlord or its designee within five (5) business days after its due date, Tenant shall pay Landlord a late charge equal to 5% of the overdue amount (provided, however, that such late charge shall not apply to any such delinquency unless either (i) such delinquency is not cured within five (5) business days after notice from Landlord, or (ii) Tenant previously received notice from Landlord of a delinquency that occurred earlier in the same calendar year); and (b) any Rent that is not paid within 10 days after its due date shall bear interest, from its due date until paid, at the lesser of 10% per annum or the highest rate permitted by Law (defined in Section 5). Tenant’s covenant to pay Rent is independent of every other covenant herein.

  

4

  

	
4

	
EXPENSES AND TAXES.

 

4.1       General Terms. In addition to Base Rent, Tenant shall pay, in accordance with Section 4.4, for each Expense Year (defined in Section 4.2.1), an amount equal to the sum of (a) Tenant’s Share of any amount (the “Expense Excess”) by which Expenses for such Expense Year exceed Expenses for the Base Year, plus (b) Tenant’s Share of any amount (the “Tax Excess”) by which Taxes for such Expense Year exceed Taxes for the Base Year. No decrease in Expenses or Taxes for any Expense Year below the corresponding amount for the Base Year shall entitle Tenant to any decrease in Base Rent or any credit against amounts due hereunder. Tenant’s Share of the Expense Excess and Tenant’s Share of the Tax Excess for any partial Expense Year shall be prorated based on the number of days in such Expense Year.

 

4.2       Definitions. As used herein, the following terms have the following meanings:

 

4.2.1        “Expense Year” means each calendar year (other than the Base Year and any preceding calendar year) in which any portion of the Term occurs.

 

4.2.2        “Expenses” means all expenses, costs and amounts that Landlord pays or accrues during the Base Year or any Expense Year because of or in connection with the ownership, management, maintenance, security, repair, replacement, restoration or operation of the Property. Landlord shall act in a reasonable manner in incurring Expenses. Expenses shall include (i) the cost of supplying all utilities, the cost of operating, repairing, maintaining and renovating the utility, telephone, mechanical, sanitary, storm-drainage, and elevator systems, and the cost of maintenance and service contracts in connection therewith; (ii) the cost of licenses, certificates, permits and inspections, the cost of contesting any Laws that may affect Expenses, and the costs of complying with any governmentally-mandated transportation-management or similar program; (iii) the cost of all insurance premiums and deductibles; (iv) the cost of landscaping and relamping; (v) the cost of parking-area operation, repair, restoration, and maintenance; (vi) a management fee in the amount (which is hereby acknowledged to be reasonable) of 3% of gross annual receipts from the Building (excluding the management fee), together with other fees and costs, including consulting fees, legal fees and accounting fees, of all contractors and consultants in connection with the management, operation, maintenance and repair of the Property; (vii) payments under any equipment-rental agreements and the fair rental value of any management office space; (viii) wages, salaries and other compensation, expenses and benefits, including taxes levied thereon, of all persons engaged in the operation, maintenance and security of the Property, and costs of training, uniforms, and employee enrichment for such persons; (ix) the costs of operation, repair, maintenance and replacement of all systems and equipment (and components thereof) of the Property; (x) the cost of janitorial, alarm, security and other services, replacement of wall and floor coverings, ceiling tiles and fixtures in Common Areas, maintenance and replacement of curbs and walkways, repair to roofs and re-roofing; (xi) rental or acquisition costs of supplies, tools, equipment, materials and personal property used in the maintenance, operation and repair of the Property; (xii) the cost of capital improvements or any other items that are (A) intended to effect economies in the operation or maintenance of the Property, reduce current or future Expenses, or enhance the safety or security of the Property or its occupants, or (B) required under any Law that is enacted, or first interpreted to apply to the Property, after the date hereof; (xiii) the cost of tenant-relation programs reasonably established by Landlord; and (xiv) payments under any existing or future reciprocal easement agreement, transportation management agreement, cost-sharing agreement or other covenant, condition, restriction or similar instrument affecting the Property.

 

Notwithstanding the foregoing, Expenses shall not include: (a) capital expenditures not described in clauses (xi) or (xii) above (in addition, any capital expenditure shall be included in Expenses only if paid or accrued after the Base Year and shall be amortized (including actual or imputed interest on the amortized cost) over the lesser of (i) the useful life of the item purchased through such capital expenditure, as reasonably determined by Landlord, or (ii) the period of time that Landlord reasonably estimates will be required for any Expense savings resulting from such capital expenditure to equal such capital expenditure; provided, however, that any capital expenditure that is included in Expenses solely on the grounds that it is intended to reduce current or future Expenses shall be so amortized over the period of time described in the preceding clause (ii)); (b) depreciation; (c) interest and principal payments of mortgage or other non-operating debts of Landlord; (d) costs of repairs to the extent Landlord is reimbursed by insurance or condemnation proceeds; (e) except as provided in clause (xiii) above, costs of leasing space in the Building, including brokerage commissions, lease concessions, rental abatements and construction allowances granted to specific tenants; (f) costs of selling, financing or refinancing the Building; (g) fines, penalties or interest resulting from late payment of Taxes or Expenses; (h) organizational expenses of creating or operating the entity that constitutes Landlord; (i) damages paid to Tenant hereunder or to other tenants of the Building under their respective leases; (j) amounts (other than management fees) paid to Landlord’s affiliates for services, but only to the extent such amounts exceed the prices charged for such services by parties having similar skill and experience; (k) fines or penalties resulting from any violations of Law, negligence or willful misconduct of Landlord or its employees, agents or contractors; (l) advertising and promotional expenses; (m) Landlord’s charitable and political contributions; (n) ground lease rental; (o) attorney’s fees and other expenses incurred in connection with negotiations or disputes with tenants or other occupants of the Building; (p) costs of services or benefits made available to other tenants of the Building but not to Tenant; (q) costs of purchasing or leasing major sculptures, paintings or other artwork (as opposed to decorations purchased or leased by Landlord for display in the Common Areas of the Building); (r) any expense for which Landlord has received actual reimbursement from a third party (other than from a tenant of the Building pursuant to its lease); (s) costs of curing defects in design or original construction of the Property; (t) costs that Landlord is entitled to recover under a warranty, except to the extent it would not be fiscally prudent to pursue legal action to recover such costs; (u) expenses (other than Parking Expenses (defined below)) of operating any commercial concession at the Project; (v) Parking Expenses (defined below), except to the extent Parking Expenses exceed parking revenues on an annual basis (as used herein, “Parking Expenses” means costs of operating, maintaining and repairing the Parking Facility, including costs of parking equipment, tickets, supplies, signs, cleaning, resurfacing, restriping, parking-garage management fees, and the wages, salaries, employee benefits and taxes for individuals working exclusively in the Parking Facility; provided, however, that Parking Expenses shall exclude (i) capital expenses, and (ii) costs of electricity, janitorial service, elevator maintenance and insurance); (w) reserves; (x) bad debt expenses; (y) costs of cleaning up Hazardous Materials, except for routine cleanup performed as part of the ordinary operation and maintenance of the Property (as used herein, “Hazardous Materials” means any material now or hereafter defined or regulated by any Law or governmental authority as radioactive, toxic, hazardous, or waste, or a chemical known to the state of California to cause cancer or reproductive toxicity, including (1) petroleum and any of its constituents or byproducts, (2) radioactive materials, (3) asbestos in any form or condition, and (4) materials regulated by any of the following, as amended from time to time, and any rules promulgated thereunder: the Comprehensive Environmental Response, Compensation and Liability Act of 1980, 42 U.S.C. §§9601 et seq.; the Resource Conservation and Recovery Act, 42 U.S.C. §§6901, et seq.; the Toxic Substances Control Act, 15 U.S.C. §§2601, et seq.; the Clean Water Act, 33 U.S.C. §§1251 et seq; the Clean Air Act, 42 U.S.C. §§7401 et seq.;The California Health and Safety Code; The California Water Code; The California Labor Code; The California Public Resources Code; and The California Fish and Game Code.); (z) wages, salaries, fees or fringe benefits (“Labor Costs”) paid to executive personnel or officers or partners of Landlord (provided, however, that if such individuals provide services directly related to the operation, maintenance or ownership of the Property that, if provided directly by a general manager or property manager or his or her general support staff, would normally be chargeable as an operating expense of a comparable office building, then the Labor Costs of such individuals may be included in Expenses to the extent of the percentage of their time that is spent providing such services to the Property); (aa) any expense for which Landlord is reimbursed (or entitled to be reimbursed) by another tenant of the Building pursuant to its lease (other than through payment of operating costs or expenses); or (bb) attorney’s fees and other expenses incurred in connection with any negotiation or dispute, other than any negotiation or dispute that (i) is with a party providing labor, materials or services the cost of which is included in Expenses, and (ii) relates to such labor, materials or services.

  

5

  

If, during any portion of the Base Year or any Expense Year, the Building is not 100% occupied (or a service provided by Landlord to tenants of the Building generally is not provided by Landlord to a tenant that provides such service itself, or any tenant of the Building is entitled to free rent, rent abatement or the like), Expenses for such year shall be determined as if the Building had been 100% occupied (and all services provided by Landlord to tenants of the Building generally had been provided by Landlord to all tenants, and no tenant of the Building had been entitled to free rent, rent abatement or the like) during such portion of such year. If a tenant of the Building reimburses Landlord on a separately measured basis, and not through payment of operating costs or expenses, for a service that is provided by Landlord to tenants of the Building generally, then, for purposes of the preceding sentence, such service shall be deemed to be provided to such tenant by such tenant itself and not by Landlord. If insurance, security or utility costs for any Expense Year are less than insurance, security or utility costs, respectively, for the Base Year, then, for purposes of determining Expenses for such Expense Year, such costs for such Expense Year shall be deemed to be increased so as to be equal to such corresponding costs for the Base Year. Notwithstanding any contrary provision hereof, Expenses for the Base Year shall exclude (a) any market-wide cost increases resulting from extraordinary circumstances, including Force Majeure (defined in Section 25.2), boycotts, strikes, conservation surcharges, embargoes or shortages, and (b) at Landlord’s option, the cost of any repair or replacement that Landlord reasonably expects will not recur on an annual or more frequent basis. If Landlord does not carry earthquake, terrorism or another type of insurance for the Building during the Base Year but carries such type of insurance for the Building during any Expense Year, then, for purposes of determining the Expense Excess for such Expense Year, Expenses for the Base Year shall be deemed to be increased by the amount of the premium Landlord would have incurred for such type of insurance during the Base Year if Landlord had maintained such type of insurance for the same period of time during the Base Year as such insurance is maintained by Landlord during such Expense Year. If, in any Expense Year, Landlord provides a new type of service (as opposed to an expansion in scope of a service or a change in a type of service) that (i) is not required by Law, (ii) is not then generally provided by the landlords of Comparable Buildings (defined in Section 25.10), (iii) is not then being provided in order to enhance the health, safety or security of the tenants, occupants and users of the Building as a result of circumstances that Landlord reasonably believes are specific to the Building and do not exist at Comparable Buildings, and (iv) was not provided by Landlord during the Base Year, then, for purposes of determining the Expense Excess for such Expense Year, Expenses for the Base Year shall be deemed to be increased by the amount that Landlord would have incurred for such service during the Base Year if Landlord had provided such service for the same period of time during the Base Year as such service is provided by Landlord during such Expense Year.

  

6

  

4.2.3        “Taxes” means all federal, state, county or local governmental or municipal taxes, fees, charges, assessments, levies, licenses or other impositions, whether general, special, ordinary or extraordinary, that are paid or accrued during the Base Year or any Expense Year (without regard to any different fiscal year used by such governmental or municipal authority) because of or in connection with the ownership, leasing or operation of the Property. Taxes shall include (a) real estate taxes; (b) general and special assessments; (c) transit taxes; (d) leasehold taxes; (e) personal property taxes imposed upon the fixtures, machinery, equipment, apparatus, systems, appurtenances, furniture and other personal property used in connection with the Property; (f) any tax on the rent, right to rent or other income from any portion of the Property or as against the business of leasing any portion of the Property; (g) any assessment, tax, fee, levy or charge imposed by any governmental agency, or by any non-governmental entity pursuant to any private cost-sharing agreement, in order to fund the provision or enhancement of any fire-protection, street-, sidewalk- or road-maintenance, refuse-removal or other service that is (or, before the enactment of Proposition 13, was) normally provided by governmental agencies to property owners or occupants without charge (other than through real property taxes); and (h) any assessment, tax, fee, levy or charge allocable or measured by the area of the Premises or by the Rent payable hereunder, including any business, gross income, gross receipts, sales or excise tax with respect to the receipt of such Rent. Any costs and expenses (including reasonable attorneys’ and consultants’ fees) incurred in attempting to protest, reduce or minimize Taxes shall be included in Taxes for the year in which they are incurred. Notwithstanding any contrary provision hereof, Taxes shall be determined without regard to any “green building” credit and shall exclude (i) all excess profits taxes, franchise taxes, gift taxes, capital stock taxes, inheritance and succession taxes, estate taxes, federal and state income taxes, and other taxes to the extent applicable to Landlord’s general or net income (as opposed to rents, receipts or income attributable to operations at the Property), (ii) any Expenses, and (iii) any items required to be paid by Tenant under Section 4.5.

 

4.3       Allocation. Landlord, in its reasonable discretion, may equitably allocate Expenses among office, retail or other portions or occupants of the Property. If Landlord incurs Expenses or Taxes for the Property together with another property, Landlord, in its reasonable discretion, shall equitably allocate such shared amounts between the Property and such other property.

 

4.4       Calculation and Payment of Expense Excess and Tax Excess.

 

4.4.1        Statement of Actual Expenses and Taxes; Payment by Tenant. Landlord shall endeavor to give to Tenant, after the end of each Expense Year, a statement (the “Statement”) setting forth the actual Expenses, Taxes, Expense Excess and Tax Excess for such Expense Year. If the amount paid by Tenant for such Expense Year pursuant to Section 4.4.2 is less or more than the sum of Tenant’s Share of the actual Expense Excess plus Tenant’s Share of the actual Tax Excess (as such amounts are set forth in such Statement), Tenant shall pay Landlord the amount of such underpayment, or receive a credit in the amount of such overpayment, with or against the Rent then or next due hereunder; provided, however, that if this Lease has expired or terminated and Tenant has vacated the Premises, Tenant shall pay Landlord the amount of such underpayment, or Landlord shall pay Tenant the amount of such overpayment (less any Rent due), within 30 days after delivery of such Statement. Any failure of Landlord to timely deliver the Statement for any Expense Year shall not diminish either party’s rights under this Section 4.

 

4.4.2        Statement of Estimated Expenses and Taxes. Landlord shall endeavor to give to Tenant, for each Expense Year, a statement (the “Estimate Statement”) setting forth Landlord’s reasonable estimates of the Expenses, Taxes, Expense Excess (the “Estimated Expense Excess”) and Tax Excess (the “Estimated Tax Excess”) for such Expense Year. Upon receiving an Estimate Statement, Tenant shall pay, with its next installment of Base Rent, an amount equal to the excess of (a) the amount obtained by multiplying (i) the sum of Tenant’s Share of the Estimated Expense Excess plus Tenant’s Share of the Estimated Tax Excess (as such amounts are set forth in such Estimate Statement), by (ii) a fraction, the numerator of which is the number of months that have elapsed in the applicable Expense Year (including the month of such payment) and the denominator of which is 12, over (b) any amount previously paid by Tenant for such Expense Year pursuant to this Section 4.4.2. Until Landlord delivers a new Estimate Statement (which Landlord may do at any time), Tenant shall pay monthly, with the monthly Base Rent installments, an amount equal to one-twelfth (1/12) of the sum of Tenant’s Share of the Estimated Expense Excess plus Tenant’s Share of the Estimated Tax Excess, as such amounts are set forth in the previous Estimate Statement. Any failure of Landlord to timely deliver any Estimate Statement shall not diminish Landlord’s rights to receive payments and revise any previous Estimate Statement under this Section 4.

 

4.4.3        Retroactive Adjustment of Taxes. Notwithstanding any contrary provision hereof, if, after Landlord’s delivery of any Statement, an increase or decrease in Taxes occurs for the applicable Expense Year or for the Base Year (whether by reason of reassessment, error, or otherwise), Taxes for such Expense Year or the Base Year, as the case may be, and the Tax Excess for such Expense Year shall be retroactively adjusted. If, as a result of such adjustment, it is determined that Tenant has under- or overpaid Tenant’s Share of such Tax Excess, Tenant shall pay Landlord the amount of such underpayment, or receive a credit in the amount of such overpayment, with or against the Rent then or next due hereunder; provided, however, that if this Lease has expired or terminated and Tenant has vacated the Premises, Tenant shall pay Landlord the amount of such underpayment, or Landlord shall pay Tenant the amount of such overpayment (less any Rent due), within 30 days after such adjustment is made.

  

7

  

4.5       Charges for Which Tenant Is Directly Responsible. Tenant shall pay, 10 days before delinquency, any taxes levied against Tenant’s equipment, furniture, fixtures and other personal property located in or about the Premises. If any such taxes are levied against Landlord or its property (or if the assessed value of Landlord’s property is increased by the inclusion therein of a value placed upon such equipment, furniture, fixtures or other personal property of Tenant), Landlord may pay such taxes (or such increased assessment) regardless of their (or its) validity, in which event Tenant, upon demand, shall repay to Landlord the amount so paid. If the Leasehold Improvements (defined in Section 7.1) are assessed for real property tax purposes at a valuation higher than the valuation at which tenant improvements conforming to Landlord’s “building standard” in other space in the Building are assessed, the Taxes levied against Landlord or the Property by reason of such excess assessed valuation shall be deemed taxes levied against Tenant’s personal property for purposes of this Section 4.5. Notwithstanding any contrary provision hereof, Tenant shall pay, 10 days before delinquency, (i) any rent tax, sales tax, service tax, transfer tax or value added tax, or any other tax respecting the rent or services described herein or otherwise respecting this transaction or this Lease; and (ii) any taxes assessed upon the possession, leasing, operation, management, maintenance, alteration, repair, use or occupancy by Tenant of any portion of the Property.

 

4.6       Books and Records. Within 60 days after receiving any Statement (the “Review Notice Period”), Tenant may give Landlord notice (“Review Notice”) stating that Tenant elects to review Landlord’s calculation of the Expense Excess and/or Tax Excess for the Expense Year to which such Statement applies and identifying with reasonable specificity the records of Landlord reasonably relating to such matters that Tenant desires to review. Within a reasonable time after receiving a timely Review Notice (and, at Landlord’s option, an executed confidentiality agreement as described below), Landlord shall deliver to Tenant, or make available for inspection at a location reasonably designated by Landlord, copies of such records. Within 60 days after such records are made available to Tenant (the “Objection Period”), Tenant may deliver to Landlord notice (an “Objection Notice”) stating with reasonable specificity any objections to the Statement, in which event Landlord and Tenant shall work together in good faith to resolve Tenant’s objections. Tenant may not deliver more than one Review Notice or more than one Objection Notice with respect to any Expense Year. If Tenant fails to give Landlord a Review Notice before the expiration of the Review Notice Period or fails to give Landlord an Objection Notice before the expiration of the Objection Period, Tenant shall be deemed to have approved the Statement. Notwithstanding any contrary provision hereof, Landlord shall not be required to deliver or make available to Tenant records relating to the Base Year, and Tenant may not object to Expenses or Taxes for the Base Year, other than in connection with the first review for an Expense Year performed by Tenant pursuant to this Section 4.6. If Tenant retains an agent to review Landlord’s records, the agent must be with a CPA firm licensed to do business in the State of California and its fees shall not be contingent, in whole or in part, upon the outcome of the review. Tenant shall be responsible for all costs of such review. The records and any related information obtained from Landlord shall be treated as confidential, and as applicable only to the Premises, by Tenant, its auditors, consultants, and any other parties reviewing the same on behalf of Tenant (collectively, “Tenant’s Auditors”). Before making any records available for review, Landlord may require Tenant and Tenant’s Auditors to execute a reasonable confidentiality agreement, in which event Tenant shall cause the same to be executed and delivered to Landlord within 30 days after receiving it from Landlord, and if Tenant fails to do so, the Objection Period shall be reduced by one day for each day by which such execution and delivery follows the expiration of such 30-day period. Notwithstanding any contrary provision hereof, Tenant may not examine Landlord’s records or dispute any Statement if any Rent remains unpaid past its due date. If, for any Expense Year, Landlord and Tenant determine that the sum of Tenant’s Share of the actual Expense Excess plus Tenant’s Share of the actual Tax Excess is less or more than the amount reported, Tenant shall receive a credit in the amount of its overpayment against Rent then or next due hereunder, or pay Landlord the amount of its underpayment with the Rent next due hereunder; provided, however, that if this Lease has expired or terminated and Tenant has vacated the Premises, Landlord shall pay Tenant the amount of its overpayment (less any Rent due), or Tenant shall pay Landlord the amount of its underpayment, within 30 days after such determination.

 

	
5

	
USE; COMPLIANCE WITH LAWS.

 

5.1       Tenant shall not (a) use the Premises for any purpose other than the Permitted Use, or (b) do anything in or about the Premises that violates any of the Rules and Regulations, damages the reputation of the Project, interferes with, injures or annoys other occupants of the Building, or constitutes a nuisance. Tenant, at its expense, shall comply with all Laws relating to (i) the operation of its business at the Project, or (ii) the use, occupancy and, other than with respect to elements of the Base Building, the condition and configuration of the Premises. If, in order to comply with any such Law, Tenant must obtain or deliver any permit, certificate or other document evidencing such compliance, Tenant shall provide a copy of such document to Landlord promptly after obtaining or delivering it. If a change to the Common Areas or any component of the Base Building becomes required under Law because any Tenant-Insured Improvement (defined in Section 10.2.2) or the installation of any trade fixture is not a type customarily required for general office use or because any use of the Premises is not general office use, Tenant, upon demand, shall (x) at Landlord’s option, either make such change at Tenant’s cost or pay Landlord the cost of making such change, and (y) pay Landlord a coordination fee equal to 10% of the cost of such change. As used herein, “Law” means any existing or future law, ordinance, regulation or requirement of any governmental authority having jurisdiction over the Project or the parties.

  

8

  

5.2       Landlord, at its expense (subject to Section 4), shall cause the Base Building and the Common Areas to comply with all Laws (including the Americans with Disabilities Act (“ADA”)) to the extent that (a) such compliance is necessary for Tenant to use the Premises for general office use in a normal and customary manner and for Tenant’s employees and visitors to have reasonably safe access to and from the Premises, or (b) Landlord’s failure to cause such compliance would impose liability upon Tenant under Law; provided, however, that Landlord shall not be required to cause such compliance to the extent non-compliance (x) is triggered by any matter that is Tenant’s responsibility under Section 5.1 or 7.3 or any other provision hereof, or (y) arises under any provision of the ADA other than Title III thereof. Notwithstanding the foregoing, Landlord may contest any alleged violation in good faith, including by applying for and obtaining a waiver or deferment of compliance, asserting any defense allowed by Law, and appealing any order or judgment to the extent permitted by Law; provided, however, that, after exhausting any rights to contest or appeal, Landlord shall perform any work necessary to comply with any final order or judgment.

 

	
6

	
SERVICES.

 

6.1       Standard Services. Landlord shall provide the following services on all days (unless otherwise stated below): (a) subject to limitations imposed by Law, customary heating, ventilation and air conditioning (“HVAC”) in season during Building HVAC Hours; (b) electricity supplied by the applicable public utility, stubbed to the Premises; (c) water supplied by the applicable public utility (i) for use in lavatories and any drinking facilities located in Common Areas within the Building, and (ii) stubbed to the Building core for use in any plumbing fixtures located in the Premises; (d) janitorial services to the Premises, except on weekends and Holidays; and (e) elevator service (subject to scheduling by Landlord, and payment of Landlord’s standard usage fee, for any freight service).

 

6.2       Above-Standard Use. Landlord shall provide HVAC service outside Building HVAC Hours if Tenant gives Landlord such prior notice and pays Landlord such hourly cost per zone as Landlord may require. Tenant shall not, without Landlord’s prior consent, use equipment that may affect the temperature maintained by the air conditioning system or consume above-Building-standard amounts of any water furnished for the Premises by Landlord pursuant to Section 6.1. If Tenant’s consumption of electricity or water exceeds the rate Landlord reasonably deems to be standard for the Building, Tenant shall pay Landlord, upon billing, the cost of such excess consumption, including any costs of installing, operating and maintaining any equipment that is installed in order to supply or measure such excess electricity or water. For purposes of the preceding sentence, Landlord confirms that Tenant’s consumption of electricity in amounts consistent with Tenant’s consumption of electricity in the first three months of the Term of this Lease (on a per square foot basis) shall not constitute excess consumption of electricity hereunder. The connected electrical load of Tenant’s incidental-use equipment shall not exceed the Building-standard electrical design load, and Tenant’s electrical usage shall not exceed the capacity of the feeders to the Project or the risers or wiring installation.

 

6.3       Interruption. Any failure to furnish, delay in furnishing, or diminution in the quality or quantity of any service resulting from any application of Law, failure of equipment, performance of maintenance, repairs, improvements or alterations, utility interruption, or event of Force Majeure (each, a “Service Interruption”) shall not render Landlord liable to Tenant, constitute a constructive eviction, or excuse Tenant from any obligation hereunder. Notwithstanding the foregoing, if all or a material portion of the Premises is made untenantable or inaccessible for more than five (5) consecutive business days after notice from Tenant to Landlord by a Service Interruption that Landlord can correct through reasonable efforts, then, as Tenant’s sole remedy, Monthly Rent shall abate for the period beginning on the day immediately following such 5-business-day period and ending on the day such Service Interruption ends, but only in proportion to the percentage of the rentable square footage of the Premises made untenantable or inaccessible.

 

	
7

	
REPAIRS AND ALTERATIONS.

 

7.1       Repairs. Subject to Section 11, Tenant, at its expense, shall perform all maintenance and repairs (including replacements) to the Premises, and keep the Premises in as good condition and repair as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, except for reasonable wear and tear and repairs that are Landlord’s express responsibility hereunder. Tenant’s maintenance and repair obligations shall include (a) all leasehold improvements in the Premises, whenever and by whomever installed or paid for, including any Tenant Improvements, any Alterations (defined in Section 7.2), and any leasehold improvements installed pursuant to any prior lease, but excluding the Base Building (the “Leasehold Improvements”); (b) all supplemental heating, ventilation and air conditioning units, kitchens (including hot water heaters, dishwashers, garbage disposals, insta-hot dispensers, and plumbing) and similar facilities exclusively serving Tenant, whether located inside or outside of the Premises, and whenever and by whomever installed or paid for; and (c) all Lines (defined in Section 23). Notwithstanding the foregoing, Landlord may, at its option, perform such maintenance and repairs on Tenant’s behalf, in which case Tenant shall pay Landlord, upon demand, the cost of such work plus a coordination fee equal to 10% of such cost. Landlord shall perform all maintenance and repairs to (i) the roof and exterior walls and windows of the Building, (ii) the Base Building, and (iii) the Common Areas. As used herein, “Base Building” means the structural portions of the Building, together with all mechanical (including HVAC), electrical, plumbing and fire/life-safety systems serving the Building in general, whether located inside or outside of the Premises.

  

9

  

7.2       Alterations. Tenant may not make any improvement, alteration, addition or change to the Premises or to any mechanical, plumbing or HVAC facilities or other systems serving the Premises (an “Alteration”) without Landlord’s prior consent, which consent shall be requested by Tenant not less than 30 days before commencement of work and shall not be unreasonably withheld by Landlord. Notwithstanding the foregoing, Landlord’s prior consent shall not be required for any Alteration that is decorative only (e.g., carpet installation or painting) and not visible from outside the Premises, provided that Landlord receives 10 business days’ prior notice. For any Alteration, (a) Tenant, before commencing work, shall deliver to Landlord, and obtain Landlord’s approval of, plans and specifications; (b) Landlord, in its discretion, may require Tenant to obtain security for performance satisfactory to Landlord; (c) Tenant shall deliver to Landlord “as built” drawings (in CAD format, if requested by Landlord), completion affidavits, full and final lien waivers, and all governmental approvals; and (d) Tenant shall pay Landlord upon demand (i) Landlord’s reasonable out-of-pocket expenses incurred in reviewing the work, and (ii) a coordination fee equal to 10% of the cost of the work; provided, however, that this clause (d) shall not apply to any Tenant Improvements.

 

7.3       Tenant Work. Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.

 

8         LANDLORD’S PROPERTY. All Leasehold Improvements shall become Landlord’s property upon installation and without compensation to Tenant. Notwithstanding the foregoing, if any Tenant-Insured Improvements are not, in Landlord’s reasonable judgment, Building-standard, then before the expiration or earlier termination hereof, Tenant shall, at Landlord’s election, either (a) at Tenant’s expense, and except as otherwise notified by Landlord, remove such Tenant-Insured Improvements (other than the Excluded Items (defined below)), repair any resulting damage to the Premises or Building, and restore the affected portion of the Premises to its condition existing before the installation of such Tenant-Insured Improvements (or, at Landlord’s election, to a Building-standard tenant-improved condition as determined by Landlord), or (b) pay Landlord an amount equal to the estimated cost of such work, as reasonably determined by Landlord. If Tenant fails to timely perform any work required under clause (a) of the preceding sentence, Landlord may perform such work at Tenant’s expense. If, when it requests Landlord’s approval of any Tenant Improvements or Alterations, Tenant specifically requests that Landlord identify any such Tenant Improvements or Alterations that, in Landlord’s judgment, are not Building-standard, Landlord shall do so when it provides such approval. As used herein, “Excluded Items” means the Tenant Improvements listed in Section 2.1 of Exhibit B-1 (as distinguished from any other improvements or alterations that may be added to the Worklist (defined in Exhibit B-1) pursuant to Exhibit B-1).

 

9         LIENS. Tenant shall keep the Project free from any lien arising out of any work performed, material furnished or obligation incurred by or on behalf of Tenant. Tenant shall remove any such lien within 10 business days after notice from Landlord, and if Tenant fails to do so, Landlord, without limiting its remedies, may pay the amount necessary to cause such removal, whether or not such lien is valid. The amount so paid, together with reasonable attorneys’ fees and expenses, shall be reimbursed by Tenant upon demand.

  

10

  

	
10

	
INDEMNIFICATION; INSURANCE.

 

10.1     Waiver and Indemnification. Tenant waives all claims against Landlord, its Security Holders (defined in Section 17), Landlord’s managing agent(s), their (direct or indirect) owners, and the beneficiaries, trustees, officers, directors, employees and agents of each of the foregoing (including Landlord, the “Landlord Parties”) for (i) any damage to person or property (or resulting from the loss of use thereof), except to the extent such damage is caused by the gross negligence or willful misconduct of any Landlord Party, or (ii) any failure to prevent or control any criminal or otherwise wrongful conduct by any third party or to apprehend any third party who has engaged in such conduct. Tenant shall indemnify, defend, protect, and hold the Landlord Parties harmless from any obligation, loss, claim, action, liability, penalty, damage, cost or expense (including reasonable attorneys’ and consultants’ fees and expenses) (each, a “Claim”) that is imposed or asserted by any third party and arises from (a) any cause in, on or about the Premises, (b) occupancy of the Premises by, or any negligence or willful misconduct of, Tenant, any party claiming by, through or under Tenant, their (direct or indirect) owners, or any of their respective beneficiaries, trustees, officers, directors, employees, agents, contractors, licensees or invitees, or (c) any breach by Tenant of any representation, covenant or other term contained herein, except to the extent such Claim arises from the gross negligence or willful misconduct of any Landlord Party.

 

10.2     Tenant’s Insurance. Tenant shall maintain the following coverages in the following amounts:

 

10.2.1      Commercial General Liability Insurance covering claims of bodily injury, personal injury and property damage arising out of Tenant’s operations and contractual liabilities, including coverage formerly known as broad form, on an occurrence basis, with combined primary and excess/umbrella limits of $3,000,000 each occurrence and $4,000,000 annual aggregate.

 

10.2.2      Property Insurance covering (i) all office furniture, trade fixtures, office equipment, free-standing cabinet work, movable partitions, merchandise and all other items of Tenant’s property in the Premises installed by, for, or at the expense of Tenant, and (ii) any Leasehold Improvements installed by or for the benefit of Tenant, whether pursuant to this Lease or pursuant to any prior lease or other agreement to which Tenant was a party (“Tenant-Insured Improvements”). Such insurance shall be written on a special cause of loss form for physical loss or damage, for the full replacement cost value (subject to reasonable deductible amounts) new without deduction for depreciation of the covered items and in amounts that meet any co-insurance clauses of the policies of insurance, and shall include coverage for damage or other loss caused by fire or other peril, including vandalism and malicious mischief, theft, water damage of any type, including sprinkler leakage, bursting or stoppage of pipes, and explosion, and providing business interruption coverage for a period of one year.

 

10.2.3      Workers’ Compensation statutory limits and Employers’ Liability limits of $1,000,000.

 

10.3     Form of Policies. The minimum limits of insurance required to be carried by Tenant shall not limit Tenant’s liability. Such insurance shall be issued by an insurance company that has an A.M. Best rating of not less than A-VIII and shall be in form and content reasonably acceptable to Landlord. Tenant’s Commercial General Liability Insurance shall (a) name the Landlord Parties and any other party designated by Landlord (“Additional Insured Parties”) as additional insureds; and (b) be primary insurance as to all claims thereunder and provide that any insurance carried by Landlord is excess and non-contributing with Tenant’s insurance. Landlord shall be designated as a loss payee with respect to Tenant’s Property Insurance on any Tenant-Insured Improvements and trade fixtures. Tenant shall deliver to Landlord, on or before the Commencement Date and at least 15 days before the expiration dates thereof, certificates from Tenant’s insurance company on the forms currently designated “ACORD 25” (Certificate of Liability Insurance) and “ACORD 28” (Evidence of Commercial Property Insurance) or the equivalent. Attached to the ACORD 25 (or equivalent) there shall be an endorsement naming the Additional Insured Parties as additional insureds, and attached to the ACORD 28 (or equivalent) there shall be an endorsement designating Landlord as a loss payee with respect to Tenant’s Property Insurance on any Tenant-Insured Improvements and trade fixtures, and each such endorsement shall be binding on Tenant’s insurance company. Upon Landlord’s request, Tenant shall deliver to Landlord, in lieu of such certificates, copies of the policies of insurance required to be carried under Section 10.2 showing that the Additional Insured Parties are named as additional insureds and that Landlord is designated as a loss payee with respect to Tenant’s Property Insurance on any Tenant-Insured Improvements and trade fixtures.

 

10.4     Subrogation. Each party waives, and shall cause its insurance carrier to waive, any right of recovery against the other party, any of its (direct or indirect) owners, or any of their respective beneficiaries, trustees, officers, directors, employees or agents for any loss of or damage to property which loss or damage is (or, if the insurance required hereunder had been carried, would have been) covered by property insurance. For purposes of this Section 10.4 only, (a) any deductible with respect to a party’s insurance shall be deemed covered by, and recoverable by such party under, valid and collectable policies of insurance, and (b) any contractor retained by Landlord to install, maintain or monitor a fire or security alarm for the Building shall be deemed an agent of Landlord.

  

11

  

10.5     Additional Insurance Obligations. Tenant shall maintain such increased amounts of the insurance required to be carried by Tenant under this Section 10, and such other types and amounts of insurance covering the Premises and Tenant’s operations therein, as may be reasonably requested by Landlord, but not in excess of the amounts and types of insurance then being required by landlords of buildings comparable to and in the vicinity of the Building.

 

11       CASUALTY DAMAGE. With reasonable promptness after discovering any damage to the Premises, or to the Common Areas necessary for access to the Premises, resulting from any fire or other casualty (a “Casualty”), Landlord shall notify Tenant of Landlord’s reasonable estimate of the time required to substantially complete repair of such damage (the “Landlord Repairs”). If, according to such estimate, the Landlord Repairs cannot be substantially completed within 270 days after they are commenced, either party may terminate this Lease upon 60 days’ notice to the other party delivered within 10 days after Landlord’s delivery of such estimate. Within 90 days after discovering any damage to the Project resulting from any Casualty, Landlord may, whether or not the Premises is affected, terminate this Lease by notifying Tenant if (i) any Security Holder terminates any ground lease or requires that any insurance proceeds be used to pay any mortgage debt; (ii) any damage to Landlord’s property is not fully covered by Landlord’s insurance policies; (iii) Landlord decides to rebuild the Building or Common Areas so that it or they will be substantially different structurally or architecturally; (iv) the damage occurs during the last 12 months of the Term; or (v) any owner, other than Landlord, of any damaged portion of the Project does not intend to repair such damage. If this Lease is not terminated pursuant to this Section 11, Landlord shall promptly and diligently perform the Landlord Repairs, subject to reasonable delays for insurance adjustment and other events of Force Majeure. The Landlord Repairs shall restore the Premises and the Common Areas necessary for access to the Premises to substantially the same condition that existed when the Casualty occurred, except for (a) any modifications required by Law or any Security Holder, and (b) any modifications to the Common Areas that are deemed desirable by Landlord, are consistent with the character of the Project, and do not materially impair access to the Premises. Notwithstanding Section 10.4, Tenant shall assign to Landlord (or its designee) all insurance proceeds payable to Tenant under Tenant’s insurance required under Section 10.2 with respect to any Tenant-Insured Improvements and trade fixtures, and if the estimated or actual cost of restoring any Tenant-Insured Improvements and trade fixtures exceeds the insurance proceeds received by Landlord from Tenant’s insurance carrier, Tenant shall pay such excess to Landlord within 15 days after Landlord’s demand. No Casualty and no restoration performed as required hereunder shall render Landlord liable to Tenant, constitute a constructive eviction, or excuse Tenant from any obligation hereunder; provided, however, that if the Premises or any Common Area necessary for Tenant’s access to the Premises is damaged by a Casualty, then, during any time that, as a result of such damage, any portion of the Premises is untenantable or inaccessible and is not occupied by Tenant, Monthly Rent shall be abated in proportion to the rentable square footage of such portion of the Premises.

 

12       NONWAIVER. No provision hereof shall be deemed waived by either party unless it is waived by such party expressly and in writing, and no waiver of any breach of any provision hereof shall be deemed a waiver of any subsequent breach of such provision or any other provision hereof. Landlord’s acceptance of Rent shall not be deemed a waiver of any preceding breach of any provision hereof, other than Tenant’s failure to pay the particular Rent so accepted, regardless of Landlord’s knowledge of such preceding breach at the time of such acceptance. No acceptance of payment of an amount less than the Rent due hereunder shall be deemed a waiver of Landlord’s right to receive the full amount of Rent due, whether or not any endorsement or statement accompanying such payment purports to effect an accord and satisfaction. No receipt of monies by Landlord from Tenant after the giving of any notice, the commencement of any suit, the issuance of any final judgment, or the termination hereof shall affect such notice, suit or judgment, or reinstate or extend the Term or Tenant’s right of possession hereunder.

 

13       CONDEMNATION. If any part of the Premises, Building or Project is taken for any public or quasi-public use by power of eminent domain or by private purchase in lieu thereof (a “Taking”) for more than 180 consecutive days, Landlord may terminate this Lease. If more than 25% of the rentable square footage of the Premises is Taken, or access to the Premises is substantially impaired as a result of a Taking, for more than 180 consecutive days, Tenant may terminate this Lease. Any such termination shall be effective as of the date possession must be surrendered to the authority, and the terminating party shall provide termination notice to the other party within 45 days after receiving written notice of such surrender date. Except as provided above in this Section 13, neither party may terminate this Lease as a result of a Taking. Tenant shall not assert any claim for compensation because of any Taking; provided, however, that Tenant may file a separate claim for any Taking of Tenant’s personal property or any fixtures that Tenant is entitled to remove upon the expiration hereof, and for moving expenses, so long as such claim does not diminish the award available to Landlord or any Security Holder and is payable separately to Tenant. If this Lease is terminated pursuant to this Section 13, all Rent shall be apportioned as of the date of such termination. If a Taking occurs and this Lease is not so terminated, Monthly Rent shall be abated for the period of such Taking in proportion to the percentage of the rentable square footage of the Premises, if any, that is subject to, or rendered inaccessible by, such Taking.

  

12

  

	
14

	
ASSIGNMENT AND SUBLETTING.

 

14.1     Transfers. Tenant shall not, without Landlord’s prior consent, assign, mortgage, pledge, hypothecate, encumber, permit any lien to attach to, or otherwise transfer this Lease or any interest hereunder, permit any assignment or other transfer hereof or any interest hereunder by operation of law, enter into any sublease or license agreement, otherwise permit the occupancy or use of any part of the Premises by any persons other than Tenant and its employees and contractors, or permit a Change of Control (defined in Section 14.6) to occur (each, a “Transfer”). If Tenant desires Landlord’s consent to any Transfer, Tenant shall provide Landlord with (i) notice of the terms of the proposed Transfer, including its proposed effective date (the “Contemplated Effective Date”), a description of the portion of the Premises to be transferred (the “Contemplated Transfer Space”), a calculation of the Transfer Premium (defined in Section 14.3), and a copy of all existing executed and/or proposed documentation pertaining to the proposed Transfer, and (ii) current financial statements of the proposed transferee (or, in the case of a Change of Control, of the proposed new controlling party(ies)) certified by an officer or owner thereof and any other information reasonably required by Landlord in order to evaluate the proposed Transfer (collectively, the “Transfer Notice”). Within 30 days after receiving the Transfer Notice, Landlord shall notify Tenant of (a) its consent to the proposed Transfer, (b) its refusal to consent to the proposed Transfer, or (c) its exercise of its rights under Section 14.4. Any Transfer made without Landlord’s prior consent shall, at Landlord’s option, be void and shall, at Landlord’s option, constitute a Default (defined in Section 19). Tenant shall pay Landlord a fee of $1,500.00 for Landlord’s review of any proposed Transfer, whether or not Landlord consents to it.

 

14.2     Landlord’s Consent. Subject to Section 14.4, Landlord shall not unreasonably withhold its consent to any proposed Transfer. Without limiting other reasonable grounds for withholding consent, it shall be deemed reasonable for Landlord to withhold consent to a proposed Transfer if:

 

14.2.1      The proposed transferee is not a party of reasonable financial strength in light of the responsibilities to be undertaken in connection with the Transfer on the date the Transfer Notice is received; or

 

14.2.2      The proposed transferee has a character or reputation or is engaged in a business that is not consistent with the quality of the Building or the Project; or

 

14.2.3      The proposed transferee is a governmental entity or a nonprofit organization; or

 

14.2.4      Intentionally omitted; or

 

14.2.5      Both (a) the proposed transferee or any of its Affiliates, on the date the Transfer Notice is received, leases or occupies (or, at any time during the 6-month period ending on the date the Transfer Notice is received, has negotiated with Landlord to lease) space in the Project or in another comparable project owned by Landlord or an Affiliate of Landlord within the Transfer Radius, and (b) as of the Contemplated Effective Date, Landlord will have space available to lease comparable to the Contemplated Transfer Space.

 

Notwithstanding any contrary provision hereof, (a) if Landlord consents to any Transfer pursuant to this Section 14.2 but Tenant does not enter into such Transfer within six (6) months thereafter, such consent shall no longer apply and such Transfer shall not be permitted unless Tenant again obtains Landlord’s consent thereto pursuant and subject to the terms of this Section 14; and (b) if Landlord unreasonably withholds its consent under this Section 14.2, Tenant’s sole remedies shall be contract damages (subject to Section 20) or specific performance, and Tenant waives all other remedies, including any right to terminate this Lease.

 

14.3     Transfer Premium. If Landlord consents to a Transfer, Tenant shall pay Landlord an amount equal to 50% of any Transfer Premium (defined below). As used herein, “Transfer Premium” means (a) in the case of an assignment, any consideration (including payment for Leasehold Improvements) paid by the assignee for such assignment, less any reasonable and customary expenses directly incurred by Tenant on account of such assignment, including brokerage fees, legal fees, and Landlord’s review fee; (b) in the case of a sublease, license or other occupancy agreement, for each month of the term of such agreement, the amount by which all rent and other consideration paid by the transferee to Tenant pursuant to such agreement (less all reasonable and customary expenses directly incurred by Tenant on account of such agreement, including brokerage fees, legal fees, construction costs and Landlord’s review fee, as amortized on a monthly, straight-line basis over the term of such agreement) exceeds the Monthly Rent payable by Tenant hereunder with respect to the Contemplated Transfer Space; and (c) in the case of a Change of Control, any consideration (including payment for Leasehold Improvements) paid by the new controlling party(ies) to the prior controlling party(ies) on account of this Lease, less Landlord’s review fee and, to the extent reasonably allocable to this Lease, any other reasonable and customary expenses directly incurred by such prior controlling party(ies) on account of such Change of Control. Payment of Landlord’s share of the Transfer Premium shall be made (x) in the case of an assignment or a Change of Control, within 10 days after Tenant or the prior controlling party(ies), as the case may be, receive(s) the consideration described above, and (y) in the case of a sublease, license or other occupancy agreement, for each month of the term of such agreement, within five (5) business days after Tenant receives the rent and other consideration described above. Notwithstanding any contrary provision of this Section 14.3, Tenant shall not be required to pay Landlord any portion of any Transfer Premium arising from any Change of Control that occurs for a good faith operating business purpose and not in order to evade the requirements of this Section 14.3.

  

13

  

14.4     Landlord’s Right to Recapture. Notwithstanding any contrary provision hereof, except in the case of a Permitted Transfer (defined in Section 14.8), a sublease (including any expansion rights) of less than 30% of the rentable square footage of the then existing Premises, or a sublease for a term (including any extension options) of less than 100% of the balance of the Term remaining on the Contemplated Effective Date (excluding any unexercised extension options), or a Change of Control, Landlord, by notifying Tenant within 30 days after receiving the Transfer Notice, may terminate this Lease with respect to the Contemplated Transfer Space as of the Contemplated Effective Date. If the Contemplated Transfer Space is less than the entire Premises, then Base Rent, Tenant’s Share, and the number of parking spaces to which Tenant is entitled under Section 1.9 shall be deemed adjusted on the basis of the percentage of the rentable square footage of the Premises retained by Tenant. Upon request of either party, the parties shall execute a written agreement prepared by Landlord memorializing such termination.

 

14.5     Effect of Consent. If Landlord consents to a Transfer, (i) such consent shall not be deemed a consent to any further Transfer, (ii) Tenant shall deliver to Landlord, promptly after execution, an executed copy of all documentation pertaining to the Transfer in form reasonably acceptable to Landlord, and (iii) Tenant shall deliver to Landlord, upon Landlord’s request, a complete statement, certified by an independent CPA or Tenant’s chief financial officer, setting forth in detail the computation of any Transfer Premium. In the case of an assignment, the assignee shall assume in writing, for Landlord’s benefit, all of Tenant’s obligations hereunder. No Transfer, with or without Landlord’s consent, shall relieve Tenant or any guarantor hereof from any liability hereunder. Notwithstanding any contrary provision hereof, Tenant, with or without Landlord’s consent, shall not enter into, or permit any party claiming by, through or under Tenant to enter into, any sublease, license or other occupancy agreement that provides for payment based in whole or in part on the net income or profit of the subtenant, licensee or other occupant thereunder.

 

14.6     Change of Control. As used herein, “Change of Control” means (a) if Tenant is a closely held professional service firm, the withdrawal or change (whether voluntary, involuntary or by operation of law) of 25% or more of its equity owners within a 12-month period; and (b) in all other cases, any transaction(s) resulting in the acquisition of a Controlling Interest (defined below) by one or more parties that did not own a Controlling Interest immediately before such transaction(s). As used herein, “Controlling Interest” means any direct or indirect equity or beneficial ownership interest in Tenant that confers upon its holder(s) the direct or indirect power to direct the ordinary management and policies of Tenant, whether through the ownership of voting securities, by contract or otherwise (but not through the ownership of voting securities listed on a recognized securities exchange).

 

14.7     Effect of Default. If Tenant is in Default, Landlord is irrevocably authorized, as Tenant’s agent and attorney-in-fact, to direct any transferee under any sublease, license or other occupancy agreement to make all payments under such agreement directly to Landlord (which Landlord shall apply towards Tenant’s obligations hereunder) until such Default is cured. Such transferee shall rely upon any representation by Landlord that Tenant is in Default, whether or not confirmed by Tenant.

 

14.8     Permitted Transfers. Notwithstanding any contrary provision hereof, if Tenant is not in Default, Tenant may, without Landlord’s consent pursuant to Section 14.1, assign this Lease to (a) an Affiliate of Tenant (other than pursuant to a merger or consolidation), (b) a successor to Tenant by merger or consolidation, or (c) a successor to Tenant by purchase of all or substantially all of Tenant’s assets (a “Permitted Transfer”), provided that (i) at least 10 business days before the Transfer, Tenant notifies Landlord of such Transfer and delivers to Landlord any documents or information reasonably requested by Landlord relating thereto (provided that if advanced notice is prohibited by a confidentiality agreement or applicable law, then Tenant shall give Landlord written notice and deliver such documents within 10 days after the effective date of the proposed Permitted Transfer), including reasonable documentation that the Transfer satisfies the requirements of this Section 14.8; (ii) in the case of an assignment pursuant to clause (a) or (c) above, the assignee executes and delivers to Landlord, at least 10 business days before the assignment (provided that if advanced notice is prohibited by a confidentiality agreement or applicable law, then Tenant shall deliver to Landlord within 10 days after the effective date of the proposed Permitted Transfer), a commercially reasonable instrument pursuant to which the assignee assumes, for Landlord’s benefit, all of Tenant’s obligations hereunder; (iii) in the case of an assignment pursuant to clause (b) above, (A) the successor entity has a net worth (as determined in accordance with GAAP, but excluding intellectual property and any other intangible assets (“Net Worth”)) immediately after the Transfer that is not less than the Net Worth of Tenant immediately before the Transfer, and (B) if Tenant is a closely held professional service firm, at least 75% of its equity owners existing 12 months before the Transfer are also equity owners of the successor entity; (iv) the transferee is qualified to conduct business in the State of California; and (v) the Transfer is made for a good faith operating business purpose and not in order to evade the requirements of this Section 14. As used herein, “Affiliate” means, with respect to any party, a person or entity that controls, is under common control with, or is controlled by such party.

  

14

  

15       SURRENDER. Upon the expiration or earlier termination hereof, and subject to Sections 8 and 11 and this Section 15, Tenant shall surrender possession of the Premises to Landlord in as good condition and repair as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, except for reasonable wear and tear and repairs that are Landlord’s express responsibility hereunder. Before such expiration or termination, Tenant, without expense to Landlord, shall (a) remove from the Premises all debris and rubbish and all furniture, equipment, trade fixtures, Lines, free-standing cabinet work, movable partitions and other articles of personal property that are owned or placed in the Premises by Tenant or any party claiming by, through or under Tenant (except for any Lines not required to be removed under Section 23), and (b) repair all damage to the Premises and Building resulting from such removal. If Tenant fails to timely perform such removal and repair, Landlord may do so at Tenant’s expense (including storage costs). If Tenant fails to remove such property from the Premises, or from storage, within 30 days after notice from Landlord, any part of such property shall be deemed, at Landlord’s option, either (x) conveyed to Landlord without compensation, or (y) abandoned.

 

16       HOLDOVER. If Tenant fails to surrender the Premises upon the expiration or earlier termination hereof, Tenant’s tenancy shall be subject to the terms and conditions hereof; provided, however, that such tenancy shall be a tenancy at sufferance only, for the entire Premises, and Tenant shall pay Monthly Rent (on a per-month basis without reduction for any partial month) at a rate equal to 150% of the Monthly Rent applicable during the last calendar month of the Term. Nothing in this Section 16 shall limit Landlord’s rights or remedies or be deemed a consent to any holdover. If Landlord is unable to deliver possession of the Premises to a new tenant or to perform improvements for a new tenant as a result of Tenant’s holdover, Tenant shall be liable for all resulting damages, including lost profits, incurred by Landlord.

 

17       SUBORDINATION; ESTOPPEL CERTIFICATES. This Lease shall be subject and subordinate to all existing and future ground or underlying leases, mortgages, trust deeds and other encumbrances against the Building or Project, all renewals, extensions, modifications, consolidations and replacements thereof (each, a “Security Agreement”), and all advances made upon the security of such mortgages or trust deeds, unless in each case the holder of such Security Agreement (each, a “Security Holder”) requires in writing that this Lease be superior thereto. Upon any termination or foreclosure (or any delivery of a deed in lieu of foreclosure) of any Security Agreement, Tenant, upon request, shall attorn, without deduction or set-off, to the Security Holder or purchaser or any successor thereto and shall recognize such party as the lessor hereunder provided that such party agrees not to disturb Tenant’s occupancy so long as Tenant timely pays the Rent and otherwise performs its obligations hereunder. Within 10 days after request by Landlord, Tenant shall execute such further instruments as Landlord may reasonably deem necessary to evidence the subordination or superiority of this Lease to any Security Agreement. Tenant waives any right it may have under Law to terminate or otherwise adversely affect this Lease or Tenant’s obligations hereunder upon a foreclosure. Within 10 business days after Landlord’s request, Tenant shall execute and deliver to Landlord a commercially reasonable estoppel certificate in favor of such parties as Landlord may reasonably designate, including current and prospective Security Holders and prospective purchasers.

 

18       ENTRY BY LANDLORD. At all reasonable times and upon no less than 24 hours prior notice to Tenant, or in an emergency, Landlord may enter the Premises to (i) inspect the Premises; (ii) show the Premises to prospective purchasers, current or prospective Security Holders or insurers, or, during the last 12 months of the Term (or while an uncured Default exists), prospective tenants; (iii) post notices of non-responsibility; or (iv) perform maintenance, repairs or alterations. At any time and without notice to Tenant, Landlord may enter the Premises to perform required services. If reasonably necessary, Landlord may temporarily close any portion of the Premises to perform maintenance, repairs or alterations. In an emergency, Landlord may use any means it deems proper to open doors to and in the Premises. No entry into or closure of any portion of the Premises pursuant to this Section 18 shall render Landlord liable to Tenant, constitute a constructive eviction, or excuse Tenant from any obligation hereunder.

 

19       DEFAULTS; REMEDIES.

 

19.1     Events of Default. The occurrence of any of the following shall constitute a “Default”:

 

19.1.1   Any failure by Tenant to pay any Rent when due unless such failure is cured within five (5) business days after notice; or

 

19.1.2   Except where a specific time period is otherwise set forth for Tenant’s cure herein (in which event Tenant’s failure to cure within such time period shall be a Default), and except as otherwise provided in this Section 19.1, any breach by Tenant of any other provision hereof where such breach continues for 30 days after notice from Landlord; provided that if such breach cannot reasonably be cured within such 30-day period, Tenant shall not be in Default as a result of such breach if Tenant diligently commences such cure within such period, thereafter diligently pursues such cure, and completes such cure within 60 days after Landlord’s notice; or

  

15

  

19.1.3   Abandonment of the Premises by Tenant; or

 

19.1.4  Any breach by Tenant of Sections 5, 14, 17 or 18 where such breach continues for more than two (2) business days after notice from Landlord; or

 

19.1.5  Tenant becomes in breach of Section 25.3.

 

If Tenant breaches a particular provision hereof (other than a provision requiring payment of Rent) on three (3) separate occasions during any 12-month period, Tenant’s subsequent breach of such provision shall be, at Landlord’s option, an incurable Default. The notice periods provided herein are in lieu of, and not in addition to, any notice periods provided by Law, and Landlord shall not be required to give any additional notice in order to be entitled to commence an unlawful detainer proceeding.

 

19.2     Remedies Upon Default. Upon any Default, Landlord shall have, in addition to any other remedies available to Landlord at law or in equity (which shall be cumulative and nonexclusive), the option to pursue any one or more of the following remedies (which shall be cumulative and nonexclusive) without any notice or demand:

 

19.2.1  Landlord may terminate this Lease, in which event Tenant shall immediately surrender the Premises to Landlord, and if Tenant fails to do so, Landlord may, without prejudice to any other remedy it may have for possession or arrearages in Rent, enter upon and take possession of the Premises and expel or remove Tenant and any other person who may be occupying the Premises or any part thereof, without being liable for prosecution or any claim or damages therefor; and Landlord may recover from Tenant the following:

 

(a)        The worth at the time of award of the unpaid Rent which has been earned at the time of such termination; plus

 

(b)        The worth at the time of award of the amount by which the unpaid Rent which would have been earned after termination until the time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus

 

(c)        The worth at the time of award of the amount by which the unpaid Rent for the balance of the Term after the time of award exceeds the amount of such Rent loss that Tenant proves could have been reasonably avoided; plus

 

(d)        Any other amount necessary to compensate Landlord for all the detriment proximately caused by Tenant’s failure to perform its obligations hereunder or which in the ordinary course of things would be likely to result therefrom, including brokerage commissions, advertising expenses, expenses of remodeling any portion of the Premises for a new tenant (whether for the same or a different use), and any special concessions made to obtain a new tenant; plus

 

(e)        At Landlord’s option, such other amounts in addition to or in lieu of the foregoing as may be permitted from time to time by Law.

 

As used in Sections 19.2.1(a) and (b), the “worth at the time of award” shall be computed by allowing interest at a rate per annum equal to the lesser of (i) the annual “Bank Prime Loan” rate cited in the Federal Reserve Statistical Release Publication G.13(415), published on the first Tuesday of each calendar month (or such other comparable index as Landlord shall reasonably designate if such rate ceases to be published) plus two (2) percentage points, or (ii) the highest rate permitted by Law. As used in Section 19.2.1(c), the “worth at the time of award” shall be computed by discounting such amount at the discount rate of the Federal Reserve Bank of San Francisco at the time of award plus 1%.

 

19.2.2  Landlord shall have the remedy described in California Civil Code § 1951.4 (lessor may continue lease in effect after lessee’s breach and abandonment and recover Rent as it becomes due, if lessee has the right to sublet or assign, subject only to reasonable limitations). Accordingly, if Landlord does not elect to terminate this Lease on account of any default by Tenant, Landlord may, from time to time, without terminating this Lease, enforce all of its rights and remedies hereunder, including the right to recover all Rent as it becomes due.

 

19.2.3  Landlord shall at all times have the rights and remedies (which shall be cumulative with each other and cumulative and in addition to those rights and remedies available under Sections 19.2.1 and 19.2.2, or any Law or other provision hereof), without prior demand or notice except as required by Law, to seek any declaratory, injunctive or other equitable relief, and specifically enforce this Lease, or restrain or enjoin a violation or breach of any provision hereof.

 

19.3     Efforts to Relet. Unless Landlord provides Tenant with express notice to the contrary, no re-entry, repossession, repair, maintenance, change, alteration, addition, reletting, appointment of a receiver or other action or omission by Landlord shall (a) be construed as an election by Landlord to terminate this Lease or Tenant’s right to possession, or to accept a surrender of the Premises, or (b) operate to release Tenant from any of its obligations hereunder. Tenant waives, for Tenant and for all those claiming by, through or under Tenant, California Civil Code § 3275 and California Code of Civil Procedure §§ 1174(c) and 1179 and any existing or future rights to redeem or reinstate, by order or judgment of any court or by any legal process or writ, this Lease or Tenant’s right of occupancy of the Premises after any termination hereof.

  

16

  

19.4     Landlord Default. Landlord shall not be in default hereunder unless it fails to begin within 30 days after notice from Tenant, or fails to pursue with reasonable diligence thereafter, the cure of any breach by Landlord of its obligations hereunder. Before exercising any remedies for a default by Landlord, Tenant shall give notice and a reasonable time to cure to any Security Holder of which Tenant has been notified.

 

20       LANDLORD EXCULPATION. Notwithstanding any contrary provision hereof, (a) the liability of the Landlord Parties to Tenant shall be limited to an amount equal to the lesser of (i) Landlord’s interest in the Building, or (ii) the equity interest Landlord would have in the Building if the Building were encumbered by third-party debt in an amount equal to 80% of the value of the Building (as such value is determined by Landlord); (b) Tenant shall look solely to Landlord’s interest in the Building for the recovery of any judgment or award against any Landlord Party; (c) no Landlord Party shall have any personal liability for any judgment or deficiency, and Tenant waives and releases such personal liability on behalf of itself and all parties claiming by, through or under Tenant; and (d) no Landlord Party shall be liable for any injury or damage to, or interference with, Tenant’s business, including loss of profits, loss of rents or other revenues, loss of business opportunity, loss of goodwill or loss of use, or for any form of special or consequential damage.

 

21       SECURITY DEPOSIT. Concurrently with its execution and delivery hereof, Tenant shall deposit with Landlord the Security Deposit, if any, as security for Tenant’s performance of its obligations hereunder. If Tenant breaches any provision hereof, Landlord may, at its option, without notice to Tenant, apply all or part of the Security Deposit to pay any past-due Rent, cure any breach by Tenant, or compensate Landlord for any other loss or damage caused by such breach. If Landlord so applies any portion of the Security Deposit, Tenant, within three (3) days after demand therefor, shall restore the Security Deposit to its original amount. The Security Deposit is not an advance payment of Rent or measure of damages. Any unapplied portion of the Security Deposit shall be returned to Tenant within 60 days after the latest to occur of (a) the expiration of the Term, (b) Tenant’s surrender of the Premises as required hereunder, or (c) determination of the final Rent due from Tenant. Landlord shall not be required to keep the Security Deposit separate from its other accounts.

 

22       INTENTIONALLY OMITTED.

 

23       COMMUNICATIONS AND COMPUTER LINES. All Lines installed pursuant to this Lease shall be (a) installed in accordance with Section 7; and (b) clearly marked with adhesive plastic labels (or plastic tags attached to such Lines with wire) to show Tenant’s name, suite number, and the purpose of such Lines (i) every six (6) feet outside the Premises (including the electrical room risers and any Common Areas), and (ii) at their termination points. Landlord may designate specific contractors for work relating to vertical Lines. Sufficient spare cables and space for additional cables shall be maintained for other occupants, as reasonably determined by Landlord. Unless otherwise notified by Landlord, Tenant, at its expense and before the expiration or earlier termination hereof, shall remove all Lines and repair any resulting damage. As used herein, “Lines” means all communications or computer wires and cables serving the Premises, whenever and by whomever installed or paid for, including any such wires or cables installed pursuant to any prior lease.

 

24       PARKING. Tenant may park in the Building’s parking facilities (the “Parking Facility”), in common with other tenants of the Building, upon the following terms and conditions. Tenant shall not use more than the number of unreserved and/or reserved parking spaces set forth in Section 1.9. Tenant shall pay Landlord, in accordance with Section 3, any fees for the parking spaces described in Section 1.9. Tenant shall pay Landlord any fees, taxes or other charges imposed by any governmental or quasi-governmental agency in connection with the Parking Facility, to the extent such amounts are allocated to Tenant by Landlord. Landlord shall not be liable to Tenant, nor shall this Lease be affected, if any parking is impaired by (or any parking charges are imposed as a result of) any Law. Tenant shall comply with all rules and regulations established by Landlord from time to time for the orderly operation and use of the Parking Facility, including any sticker or other identification system and the prohibition of vehicle repair and maintenance activities in the Parking Facility. Landlord may, in its discretion, allocate and assign parking passes among Tenant and the other tenants in the Building. Tenant’s use of the Parking Facility shall be at Tenant’s sole risk, and Landlord shall have no liability for any personal injury or damage to or theft of any vehicles or other property occurring in the Parking Facility or otherwise in connection with any use of the Parking Facility by Tenant, its employees or invitees. Landlord may alter the size, configuration, design, layout or any other aspect of the Parking Facility, and, in connection therewith, temporarily deny or restrict access to the Parking Facility, in each case without abatement of Rent or liability to Tenant. Landlord may delegate its responsibilities hereunder to a parking operator, in which case (i) such parking operator shall have all the rights of control reserved herein by Landlord, (ii) Tenant shall enter into a parking agreement with such parking operator, (iii) Tenant shall pay such parking operator, rather than Landlord, any charge established hereunder for the parking spaces, and (iv) Landlord shall have no liability for claims arising through acts or omissions of such parking operator except to the extent caused by Landlord’s gross negligence or willful misconduct. Tenant’s parking rights under this Section 24 are solely for the benefit of Tenant’s employees and invitees and such rights may not be transferred without Landlord’s prior consent, except pursuant to a Transfer permitted under Section 14.

  

17

  

25       MISCELLANEOUS.

 

25.1     Notices. No notice, demand, statement, designation, request, consent, approval, election or other communication given hereunder (“Notice”) shall be binding upon either party unless (a) it is in writing; (b) it is (i) sent by certified or registered mail, postage prepaid, return receipt requested, (ii) delivered by a nationally recognized courier service, or (iii) delivered personally; and (c) it is sent or delivered to the address set forth in Section 1.10 or 1.11, as applicable, or to such other place (other than a P.O. box) as the recipient may from time to time designate in a Notice to the other party. Any Notice shall be deemed received on the earlier of the date of actual delivery or the date on which delivery is refused, or, if Tenant is the recipient and has vacated its notice address without providing a new notice address, three (3) days after the date the Notice is deposited in the U.S. mail or with a courier service as described above.

 

25.2     Force Majeure. If either party is prevented from performing any obligation hereunder by any strike, act of God, war, terrorist act, shortage of labor or materials, governmental action, civil commotion or other cause beyond such party’s reasonable control (“Force Majeure”), such obligation shall be excused during (and any time period for the performance of such obligation shall be extended by) the period of such prevention; provided, however, that this Section 25.2 shall not (a) permit Tenant to hold over in the Premises after the expiration or earlier termination hereof, or (b) excuse any of Tenant’s obligations under Sections 3, 4, 5, 21 or 25.3 or any of Tenant’s obligations whose nonperformance would interfere with another occupant’s use, occupancy or enjoyment of its premises or the Project.

 

25.3     Representations and Covenants. Tenant represents, warrants and covenants that (a) Tenant is, and at all times during the Term will remain, duly organized, validly existing and in good standing under the Laws of the state of its formation and qualified to do business in the state of California; (b) neither Tenant’s execution of nor its performance under this Lease will cause Tenant to be in violation of any agreement or Law; (c) Tenant (and any guarantor hereof) has not, and at no time during the Term will have, (i) made a general assignment for the benefit of creditors, (ii) filed a voluntary petition in bankruptcy or suffered the filing of an involuntary petition by creditors, (iii) suffered the appointment of a receiver to take possession of all or substantially all of its assets, (iv) suffered the attachment or other judicial seizure of all or substantially all of its assets, (v) admitted in writing its inability to pay its debts as they come due, or (vi) made an offer of settlement, extension or composition to its creditors generally; and (d) each party that (other than through the passive ownership of interests traded on a recognized securities exchange) constitutes, owns, controls, or is owned or controlled by Tenant, any guarantor hereof or any subtenant of Tenant is not, and at no time during the Term will be, (i) in violation of any Laws relating to terrorism or money laundering, or (ii) among the parties identified on any list compiled pursuant to Executive Order 13224 for the purpose of identifying suspected terrorists or on the most current list published by the U.S. Treasury Department Office of Foreign Assets Control at its official website, http://www.treas.gov/ofac/tllsdn.pdf or any replacement website or other replacement official publication of such list.

 

25.4     Signs. Landlord shall include Tenant’s name in any tenant directory located in the lobby on the first floor of the Building. If any part of the Premises is located on a multi-tenant floor, Landlord, at Tenant’s cost, shall provide identifying suite signage for Tenant comparable to that provided by Landlord on similar floors in the Building. Tenant may not install (a) any signs outside the Premises, or (b) without Landlord’s prior consent in its sole and absolute discretion, any signs, window coverings, blinds or similar items that are visible from outside the Premises.

 

25.5     Supplemental HVAC. If any supplemental HVAC unit (a “Unit”) serves the Premises, then (a) Tenant shall pay the costs of all electricity consumed in the Unit’s operation, together with the cost of installing a meter to measure such consumption; (b) Tenant, at its expense, shall (i) operate and maintain the Unit in compliance with all applicable Laws and such reasonable rules and procedures as Landlord may impose; (ii) keep the Unit in as good working order and condition as exists upon its installation (or, if later, on the date Tenant takes possession of the Premises), subject to normal wear and tear and damage resulting from Casualty; (iii) maintain in effect, with a contractor reasonably approved by Landlord, a contract for the maintenance and repair of the Unit, which contract shall require the contractor, at least once every three (3) months, to inspect the Unit and provide to Tenant a report of any defective conditions, together with any recommendations for maintenance, repair or parts-replacement; (iv) follow all reasonable recommendation of such contractor; and (v) promptly provide to Landlord a copy of such contract and each report issued thereunder; (c) the Unit shall become Landlord’s property upon installation and without compensation to Tenant; provided, however, that upon Landlord’s request at the expiration or earlier termination hereof, Tenant, at its expense, shall remove the Unit and repair any resulting damage (provided, however, that if the Unit exists on the date of mutual execution and delivery hereof, Tenant shall have no obligation to remove such Unit in accordance with this clause (c)); (d) the Unit shall be deemed (i) a Leasehold Improvement (except for purposes of Section 8), and (ii) for purposes of Section 11, part of the Premises; (e) if the Unit exists on the date of mutual execution and delivery hereof, Tenant accepts the Unit in its “as is” condition, without representation or warranty as to quality, condition, fitness for use or any other matter; (f) if the Unit connects to the Building’s condenser water loop (if any), then Tenant shall pay to Landlord, as Additional Rent, Landlord’s standard one-time fee for such connection and Landlord’s standard monthly per-ton usage fee; and (g) if any portion of the Unit is located on the roof, then (i) Tenant’s access to the roof shall be subject to such reasonable rules and procedures as Landlord may impose; (ii) Tenant shall maintain the affected portion of the roof in a clean and orderly condition and shall not interfere with use of the roof by Landlord or any other tenants or licensees; and (iii) Landlord may relocate the Unit and/or temporarily interrupt its operation, without liability to Tenant, as reasonably necessary to maintain and repair the roof or otherwise operate the Building.

  

18

  

25.6     Attorneys’ Fees. In any action or proceeding between the parties, including any appellate or alternative dispute resolution proceeding, the prevailing party may recover from the other party all of its costs and expenses in connection therewith, including reasonable attorneys’ fees and costs. Tenant shall pay all reasonable attorneys’ fees and other fees and costs that Landlord incurs in interpreting or enforcing this Lease or otherwise protecting its rights hereunder (a) where Tenant has failed to pay Rent when due, or (b) in any bankruptcy case, assignment for the benefit of creditors, or other insolvency, liquidation or reorganization proceeding involving Tenant or this Lease.

 

25.7     Brokers. Tenant represents to Landlord that it has dealt only with Tenant’s Broker as its broker in connection with this Lease. Tenant shall indemnify, defend, and hold Landlord harmless from all claims of any brokers, other than Tenant’s Broker, claiming to have represented Tenant in connection with this Lease. Landlord shall indemnify, defend and hold Tenant harmless from all claims of any brokers, including Landlord’s Broker, claiming to have represented Landlord in connection with this Lease. Tenant acknowledges that any Affiliate of Landlord that is involved in the negotiation of this Lease is representing only Landlord, and that any assistance rendered by any agent or employee of such Affiliate in connection with this Lease or any subsequent amendment or other document related hereto has been or will be rendered as an accommodation to Tenant solely in furtherance of consummating the transaction on behalf of Landlord, and not as agent for Tenant.

 

25.8     Governing Law; WAIVER OF TRIAL BY JURY. This Lease shall be construed and enforced in accordance with the Laws of the State of California. THE PARTIES WAIVE, TO THE FULLEST EXTENT PERMITTED BY LAW, THE RIGHT TO TRIAL BY JURY IN ANY LITIGATION ARISING OUT OF OR RELATING TO THIS LEASE, THE RELATIONSHIP OF LANDLORD AND TENANT, TENANT’S USE OR OCCUPANCY OF THE PREMISES, AND/OR ANY CLAIM FOR INJURY OR DAMAGE OR ANY EMERGENCY OR STATUTORY REMEDY.

 

25.9     Waiver of Statutory Provisions. Each party waives California Civil Code §§ 1932(2) and 1933(4). Tenant waives (a) any rights under (i) California Civil Code §§ 1932(1), 1941, 1942, 1950.7 or any similar Law, or (ii) California Code of Civil Procedure § 1265.130; and (b) any right to terminate this Lease under California Civil Code § 1995.310.

 

25.10   Interpretation. As used herein, the capitalized term “Section” refers to a section hereof unless otherwise specifically provided herein. As used in this Lease, the terms “herein,” “hereof,” “hereto” and “hereunder” refer to this Lease and the term “include” and its derivatives are not limiting. Any reference herein to “any part” or “any portion” of the Premises, the Property or any other property shall be construed to refer to all or any part of such property. Wherever this Lease requires Tenant to comply with any Law, rule, regulation, procedure or other requirement or prohibits Tenant from engaging in any particular conduct, this Lease shall be deemed also to require Tenant to cause each of its employees, licensees, invitees and subtenants, and any other party claiming by, through or under Tenant, to comply with such requirement or refrain from engaging in such conduct, as the case may be. Wherever this Lease requires Landlord to provide a customary service or to act in a reasonable manner (whether in incurring an expense, establishing a rule or regulation, providing an approval or consent, or performing any other act), this Lease shall be deemed also to provide that whether such service is customary or such conduct is reasonable shall be determined by reference to the practices of owners of buildings (“Comparable Buildings”) that (i) are comparable to the Building in size, age, class, quality and location, and (ii) at Landlord’s option, have been, or are being prepared to be, certified under the U.S. Green Building Council’s Leadership in Energy and Environmental Design (LEED) rating system or a similar rating system. Tenant waives the benefit of any rule that a written agreement shall be construed against the drafting party.

 

25.11   Entire Agreement. This Lease sets forth the entire agreement between the parties relating to the subject matter hereof and supersedes any previous agreements (none of which shall be used to interpret this Lease). Tenant acknowledges that in entering into this Lease it has not relied upon any representation, warranty or statement, whether oral or written, not expressly set forth herein. This Lease can be modified only by a written agreement signed by both parties.

  

19

  

25.12   Other. Landlord, at its option, may cure any Default, without waiving any right or remedy or releasing Tenant from any obligation, in which event Tenant shall pay Landlord, upon demand, the cost of such cure. If any provision hereof is void or unenforceable, no other provision shall be affected. Submission of this instrument for examination or signature by Tenant does not constitute an option or offer to lease, and this instrument is not binding until it has been executed and delivered by both parties. If Tenant is comprised of two or more parties, their obligations shall be joint and several. Time is of the essence with respect to the performance of every provision hereof in which time of performance is a factor. So long as Tenant performs its obligations hereunder, Tenant shall have peaceful and quiet possession of the Premises against any party claiming by, through or under Landlord, subject to the terms hereof. Landlord may transfer its interest herein, in which event Landlord shall be released from, Tenant shall look solely to the transferee for the performance of, and the transferee shall be deemed to have assumed, all of Landlord’s obligations arising hereunder after the date of such transfer (including the return of any Security Deposit) and Tenant shall attorn to the transferee. Landlord reserves all rights not expressly granted to Tenant hereunder, including the right to make alterations to the Project. No rights to any view or to light or air over any property are granted to Tenant hereunder. The expiration or termination hereof shall not relieve either party of any obligation that accrued before, or continues to accrue after, such expiration or termination.

 

[SIGNATURES ARE ON THE FOLLOWING PAGE]

  

20

  

 

IN WITNESS WHEREOF, Landlord and Tenant have caused this Lease to be executed the day and date first above written.

 

	  	
LANDLORD:

	  	  
	  	
CA-LARKSPUR LANDING OFFICE PARK LIMITED PARTNERSHIP, a Delaware limited partnership

	  	  
	  	
By: 

	
EOP Owner GP L.L.C., a Delaware limited liability company, its general partner

	  	  	  
	  	  	
By:

	
/s/ John C. Moe

	  	  	
Name: 

	
John C. Moe

	  	  	
Title:

	
Market Managing Director

 

	  	
TENANT:

	  	  
	  	
DIGITAL DOMAIN PRODUCTIONS, INC., a Delaware corporation

	  	  
	  	
By:

	
/s/ Cliff Plumer

	  	
Name: 

	
Cliff Plumer

	  	
Title:

	
CEO

	  	  	
[chairman][president][vice-president]

	  	  	  
	  	
By:

	
/s/ Kevin Weston

	  	
Name:

	
Kevin Weston

	  	
Title:

	
CFO

	  	  	
[secretary][assistant secretary][chief

	  	  	
financial officer][assistant treasurer]

 

  

21

  

EXHIBIT A

 

LARKSPUR LANDING OFFICE PARK

LARKSPUR LANDING BUILDING 1100

LARKSPUR, CALIFORNIA

 

OUTLINE OF PREMISES

 

SUITE 255

 

Exhibit A

1

  

SUITE 270

 

 

SUITE 350

 

Exhibit A

2

  

EXHIBIT B-1

 

LARKSPUR LANDING OFFICE PARK

LARKSPUR LANDING BUILDING 1100

LARKSPUR, CALIFORNIA

 

SUITE 255 AND SUITE 270 WORK LETTER

 

As used in this Exhibit B-1 (this “Suite 255 and Suite 270 Work Letter”), the following terms shall have the following meanings:  “Agreement” means the lease of which this Suite 255 and Suite 270 Work Letter is a part, the “Premises” means Suite 255 and Suite 270, and “Tenant Improvements” means all improvements to be constructed in the Premises pursuant to this Suite 255 and Suite 270 Work Letter.  For purposes of this Exhibit B-1, “Tenant Improvement Work” means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

1         COST OF TENANT IMPROVEMENT WORK.  Except as provided in Section 2.7 below, the Tenant Improvement Work shall be performed at Landlord’s expense.

	
2

	
WORK LIST.

 

2.1         Work List.  Landlord shall perform improvements to the Premises in accordance with the following work list (for purposes of this Exhibit B-1, the “Work List”) using Building-standard methods, materials and finishes.

WORK LIST

	  	
ITEM

	
1.

	
Install Building standard carpet in the interior of the Premises.

	
2.

	
Paint the interior of the Premises using Building standard paint.

	
3.

	
Remove two (2) twenty-four inch side-light panels, frame and door on the corner office of the Premises.

 

2.2         Responsibility for Approving Work List.  Tenant shall be responsible for ensuring that all elements of the design of the Tenant Improvement Work are suitable for Tenant’s use of the Premises, and neither the preparation nor the approval of the Work List by Landlord shall relieve Tenant from such responsibility.

 

2.3         [Intentionally Omitted.]

 

2.4         [Intentionally Omitted.]

 

2.5         [Intentionally Omitted.]

 

2.6         [Intentionally Omitted.]

 

2.7         Revisions to Work List.  The Work List shall not be revised without Landlord’s agreement, which agreement may be withheld or conditioned in Landlord’s sole and absolute discretion.  If Tenant requests any revision to the Work List, Landlord shall provide Tenant with notice approving or disapproving such revision, and, if Landlord approves such revision, Landlord shall have such revision made and delivered to Tenant, together with notice of any resulting change in the cost of the Tenant Improvement Work, within 10 business days after the later of Landlord’s receipt of such request or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such execution and delivery) if such revision is material, whereupon Tenant, within one (1) business day, shall notify Landlord whether it desires to proceed with such revision.  If Landlord has commenced performance of the Tenant Improvement Work, then, in the absence of such authorization, Landlord shall have the option to continue such performance disregarding such revision.  Tenant shall reimburse Landlord, immediately upon demand, for any increase in the cost of the Tenant Improvement Work that results from such revision.

 

2.8         Time Deadlines.  Tenant shall use its best efforts to cooperate with Landlord and its contractors and other consultants to provide any necessary approvals relating to the Work List and obtain any necessary permits for the Tenant Improvement Work as soon as possible after the execution of this Agreement, and Tenant shall meet with Landlord, in accordance with a schedule determined by Landlord, to discuss the parties’ progress.

Exhibit B

1

  

	
3

	
CONSTRUCTION.

 

3.1      Contractor.  A contractor designated by Landlord (for purposes of this Exhibit B-1, the “Contractor”) shall perform the Tenant Improvement Work.  In addition, Landlord may select and/or approve of any subcontractors, mechanics and materialmen used in connection with the performance of the Tenant Improvement Work.

 

3.2      Construction

 

3.2.1           [Intentionally Omitted.]

 

3.2.2           Landlord’s Retention of Contractor.  Landlord shall independently retain the Contractor to perform the Tenant Improvement Work in accordance with the Work List.

 

3.2.3           Contractor’s Warranties.  Tenant waives all claims against Landlord relating to any defects in the Tenant Improvements; provided, however, that if, within 30 days after substantial completion of the Tenant Improvements, Tenant provides notice to Landlord of any non-latent defect in the Tenant Improvements, or if, within 11 months after substantial completion of the Tenant Improvements, Tenant provides notice to Landlord of any latent defect in the Tenant Improvements, then Landlord shall, at its option, either (a) assign to Tenant any right Landlord may have under the Construction Contract (defined below) to require the Contractor to correct, or pay for the correction of, such defect, or (b) at Tenant’s expense, use reasonable efforts to enforce such right directly against the Contractor for Tenant’s benefit.  As used in this Suite 255 and Suite 270 Work Letter, “Construction Contract” means the construction contract between Landlord and the Contractor pursuant to which the Tenant Improvements will be constructed.

	
4

	
COMPLETION.

 

4.1      Ready for Occupancy.  For purposes of Section 1.3.2.A of this Agreement, the Premises shall be deemed “Ready for Occupancy” upon the substantial completion of the Tenant Improvement Work.  Subject to Section 4.2 below, the Tenant Improvement Work shall be deemed to be “substantially complete” upon the completion of the Tenant Improvement Work pursuant to the Work List (as reasonably determined by Landlord), with the exception of any details of construction, mechanical adjustment or any other similar matter the non-completion of which does not materially interfere with Tenant’s use of the Premises.

 

4.2      Tenant Delay.  If the substantial completion of the Tenant Improvement Work is delayed (for purposes of this Exhibit B-1, a “Tenant Delay”) as a result of (a) [Intentionally Omitted]; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Suite 255 and Suite 270 Work Letter or the Lease; (d) any request by Tenant for a revision to the Work List (except to the extent such delay results from any failure of Landlord to comply with its obligations under Section 2.7 above); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of substantial completion of the Tenant Improvement Work as set forth in this Agreement; (f) any change to the base, shell or core of the Premises or Building required by the Work List; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually substantially completed, the Tenant Improvement Work shall be deemed to be substantially completed on the date on which the Tenant Improvement Work would have been substantially completed if no such Tenant Delay had occurred.

5         MISCELLANEOUS.  Notwithstanding any contrary provision of this Agreement, if Tenant defaults under this Agreement before the Tenant Improvement Work is completed, Landlord’s obligations under this Suite 255 and Suite 270 Work Letter shall be excused until such default is cured and Tenant shall be responsible for any resulting delay in the completion of the Tenant Improvement Work.  This Suite 255 and Suite 270 Work Letter shall not apply to any space other than the Premises.

Exhibit B

2

  

EXHIBIT B-2

 

LARKSPUR LANDING OFFICE PARK

LARKSPUR LANDING BUILDING 1100

LARKSPUR, CALIFORNIA

 

SUITE 350 WORK LETTER

As used in this Exhibit B-2 (this “Suite 350 Work Letter”), the following terms shall have the following meanings:  “Agreement” means the lease of which this Suite 350 Work Letter is a part, “Premises” means Suite 350, and “Tenant Improvements” means all improvements to be constructed in the Premises pursuant to this Suite 350 Work Letter. For purposes of this Exhibit B-2, “Tenant Improvement Work” means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

	
1

	
ALLOWANCE.

 

1.1         Allowance.  Tenant shall be entitled to a one-time tenant improvement allowance (for purposes of this Exhibit B-2, the “Allowance”) in the amount of $117,575.00 to be applied toward the Allowance Items (defined in Section 1.2 below).  Tenant shall be responsible for all costs associated with the Tenant Improvement Work, including the costs of the Allowance Items, to the extent such costs exceed the lesser of (a) the Allowance, or (b) the aggregate amount that Landlord is required to disburse for such purpose pursuant to this Suite 350 Work Letter.  Notwithstanding any contrary provision of this Agreement, if Tenant fails to use the entire Allowance within six (6) months following the Suite 350 Commencement Date, the unused amount shall revert to Landlord and Tenant shall have no further rights with respect thereto.

 

1.2         Disbursement.  Except as otherwise provided in this Suite 350 Work Letter, the Allowance shall be disbursed by Landlord only for the following items (the “Allowance Items”):  (a) the fees of the Architect (defined in Section 2.1 below) and the Engineers (defined in Section 2.1 below); (b) plan-check, permit and license fees relating to performance of the Tenant Improvement Work; (c) the cost of performing the Tenant Improvement Work, including after hours charges, testing and inspection costs, freight elevator usage, hoisting and trash removal costs, and contractors’ fees and general conditions; (d) the cost of any change to the base, shell or core of the Premises or Building required by the Plans (defined in Section 2.1 below) (including if such change is due to the fact that such work is prepared on an unoccupied basis), including all direct architectural and/or engineering fees and expenses incurred in connection therewith; (e) the cost of any change to the Plans or Tenant Improvement Work required by Law; (f) the Landlord Supervision Fee (defined in Section 3.2.2 below); (g) sales and use taxes; and (h) all other costs expended by Landlord in connection with the performance of the Tenant Improvement Work.

	
2

	
PLANS AND PRICING.

2.1         Selection of Architect.  Landlord shall retain the architect/space planner (for purposes of this Exhibit B-2, the “Architect”) and the engineering consultants (for purposes of this Exhibit B-2, the “Engineers”) of Landlord’s choice to prepare all architectural plans for the Premises and all engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC, life-safety, and sprinkler work in the Premises.  The plans and drawings to be prepared by the Architect and the Engineers shall be referred to in this Suite 350 Work Letter as the “Plans.”  Tenant shall be responsible for ensuring that all elements of the design of the Plans are suitable for Tenant’s use of the Premises, and neither the preparation of the Plans by the Architect or the Engineers nor Landlord’s approval of the Plans shall relieve Tenant from such responsibility.  Landlord shall cause the Architect and the Engineers to use the Required Level of Care (defined below) to cause the Plans to comply with Law; provided, however, that Tenant, not Landlord, shall be responsible for any violation of Law by the Plans resulting from Tenant’s use of the Premises for other than general office purposes.  As used herein, “Required Level of Care” means the level of care that reputable architects and engineers customarily use to cause drawings and specifications to comply with Law where such drawings and specifications are prepared for spaces in buildings comparable in quality to the Building. Tenant shall be responsible for ensuring that the Plans comply with Law to the extent Landlord is not expressly so responsible under this Section 2.1, and neither the preparation of the Plans by the Architect or the Engineers nor Landlord’s approval of the Plans shall relieve Tenant from such responsibility.  To the extent that either party (for purposes of this Exhibit B-2, the “Responsible Party”) is responsible under this Section 2.1 for causing the Plans to comply with Law, the Responsible Party may contest any alleged violation of Law in good faith, including by seeking a waiver or deferment of compliance, asserting any defense allowed by Law, and exercising any right of appeal (provided that the other party incurs no liability as a result of such contest and that, after completing such contest, the Responsible Party makes any modification to the Plans or any alteration to the Premises that is necessary to comply with any final order or judgment).

Exhibit B

1

  

2.2         Initial Programming Information.  Tenant shall deliver to Landlord, in writing, all information necessary in the judgment of Landlord, the Architect and the Engineers for the preparation of a conceptual space plan for the Premises (for purposes of this Exhibit B-2, a “Space Plan”), including layout and designation of all offices, rooms and other partitioning, their intended use, and equipment to be contained therein, the number and sizes of workstations, number and size of kitchen, copy, reception and storage areas (for purposes of this Exhibit B-2, collectively, the “Initial Programming Information”).  The Initial Programming Information shall be consistent with Landlord’s requirements for avoiding aesthetic, engineering or other conflicts with the design and function of the balance of the Building (for purposes of this Exhibit B-2, collectively, the “Landlord Requirements”) and shall otherwise be subject to Landlord’s reasonable approval.  Landlord shall provide Tenant with notice approving or reasonably disapproving the Initial Programming Information within five (5) business days after the later of Landlord’s receipt thereof or the mutual execution and delivery of this Agreement.  If Landlord disapproves the Initial Programming Information, Landlord’s notice of disapproval shall describe with reasonable specificity the basis for such disapproval and the changes that would be necessary to resolve Landlord’s objections.  If Landlord disapproves the Initial Programming Information, Tenant shall modify the Initial Programming Information and resubmit it for Landlord’s review and approval.  Such procedure shall be repeated as necessary until Landlord has approved the Initial Programming Information.

2.3         Space Plan.  After approving the Initial Programming Information, Landlord shall cause the Architect to prepare and deliver to Tenant a Space Plan that conforms to the Initial Programming Information.  Such preparation and delivery shall occur within 10 business days after the later of Landlord’s approval of the Initial Programming Information or the mutual execution and delivery of this Agreement.  Tenant shall approve or disapprove the Space Plan by notice to Landlord.  If Tenant disapproves the Space Plan, Tenant’s notice of disapproval shall specify any revisions Tenant desires in the Space Plan.  After receiving such notice of disapproval, Landlord shall cause the Architect to revise the Space Plan, taking into account the reasons for Tenant’s disapproval (provided, however, that Landlord shall not be required to cause the Architect to make any revision to the Space Plan that is inconsistent with the Landlord Requirements or that Landlord otherwise reasonably disapproves), and resubmit the Space Plan to Tenant for its approval.  Such revision and resubmission shall occur within five (5) business days after the later of Landlord’s receipt of Tenant’s notice of disapproval or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 10 business days after the later of such receipt or such execution and delivery) if such revision is material.  Such procedure shall be repeated as necessary until Tenant has approved the Space Plan.

2.4         Additional Programming Information.  After approving the Space Plan, Tenant shall deliver to Landlord, in writing, all information that, together with the Space Plan, is necessary in the judgment of Landlord, the Architect and the Engineers to complete the architectural, engineering and final architectural working drawings for the Premises in a form that is sufficient to enable subcontractors to bid on the work and to obtain all applicable permits for the Tenant Improvement Work (for purposes of this Exhibit B-2, the “Construction Drawings”), including electrical requirements, telephone requirements, special HVAC requirements, plumbing requirements, and all interior and special finishes (for purposes of this Exhibit B-2, collectively, the “Additional Programming Information”).  The Additional Programming Information shall be consistent with the Landlord Requirements and shall otherwise be subject to Landlord’s reasonable approval.  Landlord shall provide Tenant with notice approving or reasonably disapproving the Additional Programming Information within five (5) business days after the later of Landlord’s receipt thereof or the mutual execution and delivery of this Agreement.  If Landlord disapproves the Additional Programming Information, Landlord’s notice of disapproval shall describe with reasonable specificity the basis for such disapproval and the changes that would be necessary to resolve Landlord’s objections.  If Landlord disapproves the Additional Programming Information, Tenant shall modify the Additional Programming Information and resubmit it for Landlord’s review and approval.  Such procedure shall be repeated as necessary until Landlord has approved the Additional Programming Information.  If requested by Tenant, Landlord, in its sole and absolute discretion, may assist Tenant, or cause the Architect and/or the Engineers to assist Tenant, in preparing all or a portion of the Additional Programming Information; provided, however, that, whether or not the Additional Programming Information is prepared with such assistance, Tenant shall be solely responsible for the timely preparation and delivery of the Additional Programming Information and for all elements thereof and, subject to Section 1 above, all costs relating thereto.

Exhibit B

2

  

2.5         Construction Drawings. After approving the Additional Programming Information, Landlord shall cause the Architect and the Engineers to prepare and deliver to Tenant Construction Drawings that conform to the approved Space Plan and the approved Additional Programming Information.  Such preparation and delivery shall occur within 15 business days after the later of Landlord’s approval of the Additional Programming Information or the mutual execution and delivery of this Agreement.  Tenant shall approve or disapprove the Construction Drawings by notice to Landlord.  If Tenant disapproves the Construction Drawings, Tenant’s notice of disapproval shall specify any revisions Tenant desires in the Construction Drawings.  After receiving such notice of disapproval, Landlord shall cause the Architect and/or the Engineers to revise the Construction Drawings, taking into account the reasons for Tenant’s disapproval (provided, however, that Landlord shall not be required to cause the Architect or the Engineers to make any revision to the Construction Drawings that is inconsistent with the Landlord Requirements or that Landlord otherwise reasonably disapproves), and resubmit the Construction Drawings to Tenant for its approval.  Such revision and resubmission shall occur within five (5) business days after the later of Landlord’s receipt of Tenant’s notice of disapproval or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such mutual execution and delivery) if such revision is material.  Such procedure shall be repeated as necessary until Tenant has approved the Construction Drawings.  The Construction Drawings approved by Landlord and Tenant are referred to in this Suite 350 Work Letter as the “Approved Construction Drawings”.

2.6         Construction Pricing.  Within 10 business days after the Approved Construction Drawings are approved by Landlord and Tenant, Landlord shall provide Tenant with Landlord’s reasonable estimate (for purposes of this Exhibit B-2, the “Construction Pricing Proposal”) of the cost of all Allowance Items to be incurred by Tenant in connection with the performance of the Tenant Improvement Work pursuant to the Approved Construction Drawings.  Tenant shall provide Landlord with notice approving or disapproving the Construction Pricing Proposal.  If Tenant disapproves the Construction Pricing Proposal, Tenant’s notice of disapproval shall be accompanied by proposed revisions to the Approved Construction Drawings that Tenant requests in order to resolve its objections to the Construction Pricing Proposal, and Landlord shall respond as required under Section 2.7 below.  Such procedure shall be repeated as necessary until the Construction Pricing Proposal is approved by Tenant.  Upon Tenant’s approval of the Construction Pricing Proposal, Landlord may purchase the items set forth in the Construction Pricing Proposal and commence construction relating to such items.

2.7         Revisions to Approved Construction Drawings.  If Tenant requests any revision to the Approved Construction Drawings, Landlord shall provide Tenant with notice approving or reasonably disapproving such revision, and, if Landlord approves such revision, Landlord shall have such revision made and delivered to Tenant, together with notice of any resulting change in the most recent Construction Pricing Proposal, if any, within 10 business days after the later of Landlord’s receipt of such request or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such execution and delivery) if such revision is material, whereupon Tenant, within one (1) business day, shall notify Landlord whether it desires to proceed with such revision.  If Landlord has commenced performance of the Tenant Improvement Work, then, in the absence of such authorization, Landlord shall have the option to continue such performance disregarding such revision.  Landlord shall not revise the Approved Construction Drawings without Tenant’s consent, which shall not be unreasonably withheld, conditioned or delayed.

2.8         Time Deadlines.  Tenant shall use its best efforts to cooperate with Landlord and its architect, engineers and other consultants to complete all phases of the Plans, approve the Construction Pricing Proposal and obtain the permits for the Tenant Improvement Work as soon as possible after the execution of this Agreement, and Tenant shall meet with Landlord, in accordance with a schedule determined by Landlord, to discuss the parties’ progress.  Without limiting the foregoing, Tenant shall approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline (defined below).  As used in this Suite 350 Work Letter, “Tenant’s Approval Deadline” means August 30, 2011; provided, however, that Tenant’s Approval Deadline shall be extended by one day for each day, if any, by which Tenant’s approval of the Construction Pricing Proposal pursuant to Section 2.6 above is delayed by any failure of Landlord to perform its obligations under this Section 2.

	
3

	
CONSTRUCTION.

3.1         Contractor.  A contractor designated by Landlord (for purposes of this Exhibit B-2, the “Contractor”) shall perform the Tenant Improvement Work.  In addition, Landlord may select and/or approve of any subcontractors, mechanics and materialmen used in connection with the performance of the Tenant Improvement Work; provided, however, that the electrical subcontractor for the Tenant Improvements shall be W. Bradley Electric, Inc. (“Initial Electrician”) so long as (a) the Initial Electrician agrees to the Landlord’s standard contracting requirements, (b) the Initial Electrician remains willing and able to perform in accordance therewith and (c) the Initial Electrician does perform in accordance therewith.  If any of the foregoing conditions are no longer satisfied, Landlord may replace (or cause the Contractor to replace) the Initial Electrician with a new subcontractor to complete the performance of the Tenant Improvement Work.

Exhibit B

3

  

3.2      Construction.

3.2.1           Over-Allowance Amount.  If the Construction Pricing Proposal exceeds the Allowance, then, concurrently with its delivery to Landlord of approval of the Construction Pricing Proposal, Tenant shall deliver to Landlord cash in the amount of such excess (for purposes of this Exhibit B-2, the “Over-Allowance Amount”).  Any Over-Allowance Amount shall be disbursed by Landlord before the Allowance and pursuant to the same procedure as the Allowance.  After the Construction Pricing Proposal is approved by Tenant, if any revision is made to the Approved Construction Drawings or the Tenant Improvement Work that increases the Construction Pricing Proposal, or if the Construction Pricing Proposal is otherwise increased to reflect the actual cost of all Allowance Items to be incurred by Tenant in connection with the performance of the Tenant Improvement Work pursuant to the Approved Construction Drawings, then Tenant shall deliver any resulting Over-Allowance Amount (or any resulting increase in the Over-Allowance Amount) to Landlord immediately upon Landlord’s request.

3.2.2           Landlord’s Retention of Contractor.  Landlord shall independently retain the Contractor to perform the Tenant Improvement Work in accordance with the Approved Construction Drawings.  Tenant shall pay a construction supervision and management fee (for purposes of this Exhibit B-2, the “Landlord Supervision Fee”) to Landlord in an amount equal to 0% of the aggregate amount of all Allowance Items other than the Landlord Supervision Fee.

3.2.3           Contractor’s Warranties.  Tenant waives all claims against Landlord relating to any defects in the Tenant Improvements; provided, however, that if, within 30 days after substantial completion of the Tenant Improvements, Tenant provides notice to Landlord of any non-latent defect in the Tenant Improvements, or if, within 11 months after substantial completion of the Tenant Improvements, Tenant provides notice to Landlord of any latent defect in the Tenant Improvements, then Landlord shall, at its option, either (a) assign to Tenant any right Landlord may have under the Construction Contract (defined below) to require the Contractor to correct, or pay for the correction of, such defect, or (b) at Tenant’s expense, use reasonable efforts to enforce such right directly against the Contractor for Tenant’s benefit.  As used in this Suite 350 Work Letter, “Construction Contract” means the construction contract between Landlord and the Contractor pursuant to which the Tenant Improvements will be constructed.

4           COMPLETION.   Tenant acknowledges and agrees that the Tenant Improvement Work may be performed during Building HVAC Hours before or after the Suite 350 Commencement Date.  Landlord and Tenant shall cooperate with each other in order to enable the Tenant Improvement Work to be performed in a timely manner and with as little inconvenience to the operation of Tenant’s business as is reasonably possible.  Notwithstanding any contrary provision of this Agreement, any delay in the completion of the Tenant Improvement Work or inconvenience suffered by Tenant during the performance of the Tenant Improvement Work shall not delay the Suite 350 Commencement Date, nor shall it subject Landlord to any liability for any loss or damage resulting therefrom or entitle Tenant to any credit, abatement or adjustment of rent or other sums payable under the Lease.

5         MISCELLANEOUS.  Notwithstanding any contrary provision of this Agreement, if Tenant defaults under this Agreement before the Tenant Improvement Work is completed, Landlord’s obligations under this Suite 350 Work Letter shall be excused until such default is cured and Tenant shall be responsible for any resulting delay in the completion of the Tenant Improvement Work.  This Suite 350 Work Letter shall not apply to any space other than the Premises.

Exhibit B

4

  

EXHIBIT C

 

LARKSPUR LANDING OFFICE PARK

LARKSPUR LANDING BUILDING 1100

LARKSPUR, CALIFORNIA

CONFIRMATION LETTER

 

_____________________, 20__

	
To:

	
_______________________

	
  

	
_______________________

	
  

	
_______________________

	
  

	
_______________________

	
Re:

	
Office Lease (the “Lease”) dated ______________, 2011, between CA-LARKSPUR LANDING OFFICE PARK LIMITED PARTNERSHIP, a Delaware limited partnership (“Landlord”), and DIGITAL DOMAIN PRODUCTIONS, INC., a Delaware corporation (“Tenant”), concerning Suite 255 and Suite 270 on the second floor of the building located at 1100 Larkspur Landing Circle, Larkspur, California.

 

Lease ID: _____________________________

Business Unit Number: __________________

Dear _________________:

 

In accordance with the Lease, Tenant accepts possession of the Premises and confirms the following:

 

	
  

	
1.

	
The Suite 255 and Suite 270 Commencement Date is _____________ and the Expiration Date is November 30, 2011.

 

	
  

	
2.

	
The exact number of rentable square feet within the Premises is 9,509 square feet.

 

	
  

	
3.

	
Tenant’s Share with respect to Suite 255 and Suite 270, based upon the exact number of rentable square feet within the Premises, is 11.5673%.

 

Please acknowledge the foregoing by signing all three (3) counterparts of this letter in the space provided below and returning two (2) fully executed counterparts to my attention.  Please note that, pursuant to Section 2.1.1 of the Lease, if Tenant fails to execute and return (or, by notice to Landlord, reasonably object to) this letter within ten (10) days after receiving it, Tenant shall be deemed to have executed and returned it without exception.

 

	
“Landlord”:

	  
	
CA-LARKSPUR LANDING OFFICE PARK LIMITED PARTNERSHIP, a Delaware limited partnership

	  
	
   

	
By:  

	
EOP Owner GP L.L.C., a Delaware limited liability company, its general partner

	  	  	  
	  	  	
By:

	
      

	  	  	
Name:  

	
      

	  	  	
Title:

	
      

Exhibit C

1

  

	
Agreed and Accepted as of                , 2011.

	  
	
“Tenant”:

	  
	
DIGITAL DOMAIN PRODUCTIONS, INC., a Delaware corporation

	  
	
By:

	
      

	
Name:  

	
      

	
Title:

	
      

Exhibit C

2

  

EXHIBIT D

 

LARKSPUR LANDING OFFICE PARK

LARKSPUR LANDING BUILDING 1100

LARKSPUR, CALIFORNIA

RULES AND REGULATIONS

 

Tenant shall comply with the following rules and regulations (as modified or supplemented from time to time, the “Rules and Regulations”).  Landlord shall not be responsible to Tenant for the nonperformance of any of the Rules and Regulations by any other tenants or occupants of the Project.  In the event of any conflict between the Rules and Regulations and the other provisions of this Lease, the latter shall control.

 

1.           Tenant shall not alter any lock or install any new or additional locks or bolts on any doors or windows of the Premises without obtaining Landlord’s prior consent.  Tenant shall bear the cost of any lock changes or repairs required by Tenant.  Two (2) keys will be furnished by Landlord for the Premises, and any additional keys required by Tenant must be obtained from Landlord at a reasonable cost to be established by Landlord.  Upon the termination of this Lease, Tenant shall restore to Landlord all keys of stores, offices and toilet rooms furnished to or otherwise procured by Tenant, and if any such keys are lost, Tenant shall pay Landlord the cost of replacing them or of changing the applicable locks if Landlord deems such changes necessary.

 

2.           All doors opening to public corridors shall be kept closed at all times except for normal ingress and egress to the Premises.

 

3.           Landlord may close and keep locked all entrance and exit doors of the Building during such hours as are customary for comparable buildings in the vicinity of the Building.  Tenant shall cause its employees, agents, contractors, invitees and licensees who use Building doors during such hours to securely close and lock them after such use.  Any person entering or leaving the Building during such hours, or when the Building doors are otherwise locked, may be required to sign the Building register, and access to the Building may be refused unless such person has proper identification or has a previously arranged access pass.  Landlord will furnish passes to persons for whom Tenant requests them.  Tenant shall be responsible for all persons for whom Tenant requests passes and shall be liable to Landlord for all acts of such persons.  Landlord and its agents shall not be liable for damages for any error with regard to the admission or exclusion of any person to or from the Building.  In case of invasion, mob, riot, public excitement or other commotion, Landlord may prevent access to the Building or the Project during the continuance thereof by any means it deems appropriate for the safety and protection of life and property.

 

4.           No furniture, freight or equipment shall be brought into the Building without prior notice to Landlord.  All moving activity into or out of the Building shall be scheduled with Landlord and done only at such time and in such manner as Landlord designates.  Landlord may prescribe the weight, size and position of all safes and other heavy property brought into the Building and also the times and manner of moving the same in and out of the Building.  Safes and other heavy objects shall, if considered necessary by Landlord, stand on supports of such thickness as is necessary to properly distribute the weight.  Landlord will not be responsible for loss of or damage to any such safe or property.  Any damage to the Building, its contents, occupants or invitees resulting from Tenant’s moving or maintaining any such safe or other heavy property shall be the sole responsibility and expense of Tenant (notwithstanding Sections 7 and 10.4 of this Lease).

 

5.           No furniture, packages, supplies, equipment or merchandise will be received in the Building or carried up or down in the elevators, except between such hours, in such specific elevator and by such personnel as shall be designated by Landlord.

 

6.           Employees of Landlord shall not perform any work or do anything outside their regular duties unless under special instructions from Landlord.

 

7.           No sign, advertisement, notice or handbill shall be exhibited, distributed, painted or affixed by Tenant on any part of the Premises or the Building without Landlord’s prior consent.  Tenant shall not disturb, solicit, peddle or canvass any occupant of the Project.

 

8.           The toilet rooms, urinals, wash bowls and other apparatus shall not be used for any purpose other than that for which they were constructed, and no foreign substance shall be thrown therein.  Notwithstanding Sections 7 and 10.4 of this Lease, Tenant shall bear the expense of any breakage, stoppage or damage resulting from any violation of this rule by Tenant or any of its employees, agents, contractors, invitees or licensees.

 

Exhibit D

1

  

9.           Tenant shall not overload the floor of the Premises, or mark, drive nails or screws or drill into the partitions, woodwork or drywall of the Premises, or otherwise deface the Premises, without Landlord’s prior consent.  Tenant shall not purchase bottled water, ice, towel, linen, maintenance or other like services from any person not approved by Landlord.

 

10.         Except for vending machines intended for the sole use of Tenant’s employees and invitees, no vending machine or machines other than fractional horsepower office machines shall be installed, maintained or operated in the Premises without Landlord’s prior consent.

 

11.         No inflammable, explosive or dangerous fluids or substances shall be used or kept by Tenant in the Premises or about the Project, except for such substances as are typically found in similar premises used for general office purposes and are being used by Tenant in a safe manner and in accordance with all Laws.  Without limiting the foregoing, Tenant shall not, without Landlord’s prior consent, use, store, install, disturb, spill, remove, release or dispose of, within or about the Premises or any other portion of the Project, any asbestos-containing materials or any solid, liquid or gaseous material now or subsequently considered toxic or hazardous under the provisions of 42 U.S.C. Section 9601 et seq. or any other applicable environmental Law.  Tenant shall comply with all Laws pertaining to and governing the use of these materials by Tenant and shall remain solely liable for the costs of abatement and removal.  No burning candle or other open flame shall be ignited or kept by Tenant in the Premises or about the Project.

 

12.         Tenant shall not, without Landlord’s prior consent, use any method of heating or air conditioning other than that supplied by Landlord.

 

13.         Tenant shall not use or keep any foul or noxious gas or substance in or on the Premises, or occupy or use the Premises in a manner offensive or objectionable to Landlord or other occupants of the Project by reason of noise, odors or vibrations, or interfere with other occupants or those having business therein, whether by the use of any musical instrument, radio, CD player or otherwise.  Tenant shall not throw anything out of doors, windows or skylights or down passageways.

 

14.         Tenant shall not bring into or keep within the Project, the Building or the Premises any animals (other than service animals), birds, aquariums, or, except in areas designated by Landlord, bicycles or other vehicles.

 

15.         No cooking shall be done in the Premises, nor shall the Premises be used for lodging, for living quarters or sleeping apartments, or for any improper, objectionable or immoral purposes.  Notwithstanding the foregoing, Underwriters’ laboratory-approved equipment and microwave ovens may be used in the Premises for heating food and brewing coffee, tea, hot chocolate and similar beverages for employees and invitees, provided that such use complies with all Laws.

 

16.         The Premises shall not be used for manufacturing or for the storage of merchandise except to the extent such storage may be incidental to the Permitted Use.  Tenant shall not occupy the Premises as an office for a messenger-type operation or dispatch office, public stenographer or typist, or for the manufacture or sale of liquor, narcotics or tobacco, or as a medical office, a barber or manicure shop, or an employment bureau, without Landlord’s prior consent.  Tenant shall not engage or pay any employees in the Premises except those actually working for Tenant in the Premises, nor advertise for laborers giving an address at the Premises.

 

17.         Landlord may exclude from the Project any person who, in Landlord’s judgment, is intoxicated or under the influence of liquor or drugs, or who violates any of these Rules and Regulations.

 

18.         Tenant shall not loiter in or on the entrances, corridors, sidewalks, lobbies, courts, halls, stairways, elevators, vestibules or any Common Areas for the purpose of smoking tobacco products or for any other purpose, nor in any way obstruct such areas, and shall use them only as a means of ingress and egress for the Premises.

 

19.         Tenant shall not waste electricity, water or air conditioning, shall cooperate with Landlord to ensure the most effective operation of the Building’s heating and air conditioning system, and shall not attempt to adjust any controls.  Tenant shall install and use in the Premises only ENERGY STAR rated equipment, where available.  Tenant shall use recycled paper in the Premises to the extent consistent with its business requirements.

 

20.         Tenant shall store all its trash and garbage inside the Premises.  No material shall be placed in the trash or garbage receptacles if, under Law, it may not be disposed of in the ordinary and customary manner of disposing of trash and garbage in the vicinity of the Building.  All trash, garbage and refuse disposal shall be made only through entryways and elevators provided for such purposes at such times as Landlord shall designate.  Tenant shall comply with Landlord’s recycling program, if any.

Exhibit D

2

  

21.         Tenant shall comply with all safety, fire protection and evacuation procedures and regulations established by Landlord or any governmental agency.

 

22.         Any persons employed by Tenant to do janitorial work shall be subject to Landlord’s prior consent and, while in the Building and outside of the Premises, shall be subject to the control and direction of the Building manager (but not as an agent or employee of such manager or Landlord), and Tenant shall be responsible for all acts of such persons.

 

23.         No awning or other projection shall be attached to the outside walls of the Building without Landlord’s prior consent.  Other than Landlord’s Building-standard window coverings, no curtains, blinds, shades or screens shall be attached to or hung in, or used in connection with, any window or door of the Premises.  All electrical ceiling fixtures hung in the Premises or spaces along the perimeter of the Building must be fluorescent and/or of a quality, type, design and a warm white bulb color approved in advance by Landlord.  Neither the interior nor exterior of any windows shall be coated or otherwise sunscreened without Landlord’s prior consent.  Tenant shall abide by Landlord’s regulations concerning the opening and closing of window coverings.

 

24.         Tenant shall not obstruct any sashes, sash doors, skylights, windows or doors that reflect or admit light or air into the halls, passageways or other public places in the Building, nor shall Tenant place any bottles, parcels or other articles on the windowsills.

 

25.         Tenant must comply with requests by Landlord concerning the informing of their employees of items of importance to the Landlord.

 

26.         Tenant must comply with the State of California “No-Smoking” law set forth in California Labor Code Section 6404.5 and with any local “No-Smoking” ordinance that is not superseded by such law.

 

27.         Tenant shall cooperate in any reasonable safety or security program developed by Landlord or required by Law.

 

28.         All office equipment of an electrical or mechanical nature shall be placed by Tenant in the Premises in settings approved by Landlord, to absorb or prevent any vibration, noise or annoyance.

 

29.         Tenant shall not use any hand trucks except those equipped with rubber tires and rubber side guards.

 

30.         No auction, liquidation, fire sale, going-out-of-business or bankruptcy sale shall be conducted in the Premises without Landlord’s prior consent.

 

31.         Without Landlord’s prior consent, Tenant shall not use the name of the Project or Building or use pictures or illustrations of the Project or Building in advertising or other publicity or for any purpose other than as the address of the business to be conducted by Tenant in the Premises.

 

Landlord may from time to time modify or supplement these Rules and Regulations in a manner that, in Landlord’s reasonable judgment, is appropriate for the management, safety, care and cleanliness of the Premises, the Building, the Common Areas and the Project, for the preservation of good order therein, and for the convenience of other occupants and tenants thereof.  Landlord may waive any of these Rules and Regulations for the benefit of any tenant, but no such waiver shall be construed as a waiver of such Rule and Regulation in favor of any other tenant nor prevent Landlord from thereafter enforcing such Rule and Regulation against any tenant.

Exhibit D

3

  

EXHIBIT E

LARKSPUR LANDING OFFICE PARK

LARKSPUR LANDING BUILDING 1100

LARKSPUR, CALIFORNIA

JUDICIAL REFERENCE

 

IF THE JURY-WAIVER PROVISIONS OF SECTION 25.8 OF THIS LEASE ARE NOT ENFORCEABLE UNDER CALIFORNIA LAW, THE PROVISIONS SET FORTH BELOW SHALL APPLY.

 

It is the desire and intention of the parties to agree upon a mechanism and procedure under which controversies and disputes arising out of this Lease or related to the Premises will be resolved in a prompt and expeditious manner.  Accordingly, except with respect to actions for unlawful or forcible detainer or with respect to the prejudgment remedy of attachment, any action, proceeding or counterclaim brought by either party hereto against the other (and/or against its officers, directors, employees, agents or subsidiaries or affiliated entities) on any matters arising out of or in any way connected with this Lease, Tenant’s use or occupancy of the Premises and/or any claim of injury or damage, whether sounding in contract, tort, or otherwise, shall be heard and resolved by a referee under the provisions of the California Code of Civil Procedure, Sections 638 — 645.1, inclusive (as same may be amended, or any successor statute(s) thereto) (the “Referee Sections”).  Any fee to initiate the judicial reference proceedings and all fees charged and costs incurred by the referee shall be paid by the party initiating such procedure (except that if a reporter is requested by either party, then a reporter shall be present at all proceedings where requested and the fees of such reporter – except for copies ordered by the other parties – shall be borne by the party requesting the reporter); provided however, that allocation of the costs and fees, including any initiation fee, of such proceeding shall be ultimately determined in accordance with Section 25.6 of this Lease.  The venue of the proceedings shall be in the county in which the Premises is located.  Within 10 days of receipt by any party of a request to resolve any dispute or controversy pursuant to this Exhibit E, the parties shall agree upon a single referee who shall try all issues, whether of fact or law, and report a finding and judgment on such issues as required by the Referee Sections.  If the parties are unable to agree upon a referee within such 10-day period, then any party may thereafter file a lawsuit in the county in which the Premises is located for the purpose of appointment of a referee under the Referee Sections.  If the referee is appointed by the court, the referee shall be a neutral and impartial retired judge with substantial experience in the relevant matters to be determined, from Jams/Endispute, Inc., ADR Services, Inc. or a similar mediation/arbitration entity approved by each party in its sole and absolute discretion.  The proposed referee may be challenged by any party for any of the grounds listed in the Referee Sections.  The referee shall have the power to decide all issues of fact and law and report his or her decision on such issues, and to issue all recognized remedies available at law or in equity for any cause of action that is before the referee, including an award of attorneys’ fees and costs in accordance with this Lease.  The referee shall not, however, have the power to award punitive damages, nor any other damages that are not permitted by the express provisions of this Lease, and the parties waive any right to recover any such damages.  The parties may conduct all discovery as provided in the California Code of Civil Procedure, and the referee shall oversee discovery and may enforce all discovery orders in the same manner as any trial court judge, with rights to regulate discovery and to issue and enforce subpoenas, protective orders and other limitations on discovery available under California Law.  The reference proceeding shall be conducted in accordance with California Law (including the rules of evidence), and in all regards, the referee shall follow California Law applicable at the time of the reference proceeding.  The parties shall promptly and diligently cooperate with one another and the referee, and shall perform such acts as may be necessary to obtain a prompt and expeditious resolution of the dispute or controversy in accordance with the terms of this Exhibit E.  In this regard, the parties agree that the parties and the referee shall use best efforts to ensure that (a) discovery be conducted for a period no longer than 6 months from the date the referee is appointed, excluding motions regarding discovery, and (b) a trial date be set within 9 months of the date the referee is appointed.   In accordance with Section 644 of the California Code of Civil Procedure, the decision of the referee upon the whole issue must stand as the decision of the court, and upon the filing of the statement of decision with the clerk of the court, or with the judge if there is no clerk, judgment may be entered thereon in the same manner as if the action had been tried by the court.   Any decision of the referee and/or judgment or other order entered thereon shall be appealable to the same extent and in the same manner that such decision, judgment, or order would be appealable if rendered by a judge of the superior court in which venue is proper hereunder.  The referee shall in his/her statement of decision set forth his/her findings of fact and conclusions of law. The parties intend this general reference agreement to be specifically enforceable in accordance with the Code of Civil Procedure.  Nothing in this Exhibit E shall prejudice the right of any party to obtain provisional relief or other equitable remedies from a court of competent jurisdiction as shall otherwise be available under the Code of Civil Procedure and/or applicable court rules.

Exhibit E

1

  

EXHIBIT F

LARKSPUR LANDING OFFICE PARK

LARKSPUR LANDING BUILDING 1100

LARKSPUR, CALIFORNIA

 

ADDITIONAL PROVISIONS

	
1.

	
Asbestos Notification.  Tenant acknowledges that Tenant has received the asbestos notification letter attached to this Lease as Exhibit G hereto, disclosing the existence of asbestos in the Building.  As part of Tenant’s obligations under this Lease, Tenant agrees to comply with the California “Connelly Act” and other applicable Laws, including providing copies of Landlord’s asbestos notification letter to all of Tenant’s “employees” and “owners”, as those terms are defined in the Connelly Act and other applicable Laws.

	
2.

	
Provisions Required Under Existing Security Agreement.  Notwithstanding any contrary provision of this Lease:

	
  

	
A.

	
Permitted Use.  No portion of the Premises shall be used for any of the following uses:  any pornographic or obscene purposes, any commercial sex establishment, any pornographic, obscene, nude or semi-nude performances, modeling, materials, activities, or sexual conduct or any other use that, as of the time of the execution hereof, has or could reasonably be expected to have a material adverse effect on the Property or its use, operation or value.

	
  

	
B.

	
Subordination and Attornment.  This Lease shall be subject and subordinate to any Security Agreement (other than a ground lease) existing as of the date of mutual execution and delivery of this Lease (as the same may be amended, restated, replaced, supplemented or otherwise modified from time to time, an “Existing Security Agreement”) or any loan document secured by any Existing Security Agreement (an “Existing Loan Document”).  In the event of the enforcement by any Security Holder of any remedy under any Existing Security Agreement or Existing Loan Document, Tenant shall, at the option of the Security Holder or of any other person or entity succeeding to the interest of the Security Holder as a result of such enforcement, attorn to the Security Holder or to such person or entity and shall recognize the Security Holder or such successor in the interest as lessor under this Lease without change in the provisions thereof; provided, however, the Security Holder or such successor in interest shall not be liable for or bound by (i) any payment of an installment of rent or additional rent which may have been made more than thirty (30) days before the due date of such installment, (ii) any act or omission of or default by Landlord under this Lease (but the Security Holder, or such successor, shall be subject to the continuing obligations of Landlord to the extent arising from and after such succession to the extent of the Security Holder’s, or such successor’s, interest in the Property), (iii) any credits, claims, setoffs or defenses which Tenant may have against Landlord, or (iv) any obligation under this Lease to maintain a fitness facility at the Property.  Tenant, upon the reasonable request by the Security Holder or such successor in interest, shall execute and deliver an instrument or instruments confirming such attornment.  Notwithstanding the foregoing, in the event the Security Holder under any Existing Security Agreement or Existing Loan Document shall have entered into a separate subordination, attornment and non-disturbance agreement directly with Tenant governing Tenant’s obligation to attorn to the Security Holder or such successor in interest as lessor, the terms and provisions of such agreement shall supersede the provisions of this Subsection.

	
  

	
C.

	
Proceeds.

	
  

	
1.

	
As used herein, “Proceeds” means any compensation, awards, proceeds, damages, claims, insurance recoveries, causes or rights of action (whenever accrued) or payments which Landlord may receive or to which Landlord may become entitled with respect to the Property or any part thereof (other than payments received in connection with any liability or loss of rental value or business interruption insurance) in connection with any taking by condemnation or eminent domain (“Taking”) of, or any casualty or other damage or injury to, the Property or any part thereof.

	
  

	
2.

	
Nothing in this Lease shall be deemed to entitle Tenant to receive and retain Proceeds except those that may be specifically awarded to it in condemnation proceedings because of the Taking of its trade fixtures and its leasehold improvements which have not become part of the Property and such business loss as Tenant may specifically and separately establish.  Nothing in the preceding sentence shall be deemed to expand any right Tenant may have under this Lease to receive or retain any Proceeds.

Exhibit F

1

  

	
  

	
3.

	
Nothing in this Lease shall be deemed to prevent Proceeds from being held and disbursed by any Security Holder under any Existing Loan Documents in accordance with the terms of such Existing Loan Documents.  However, if, in the event of any casualty or partial Taking, any obligation of Landlord under this Lease to restore the Premises or the Building is materially diminished by the operation of the preceding sentence, then Landlord, as soon as reasonably practicable after the occurrence of such casualty or partial Taking, shall provide written notice to Tenant describing such diminution with reasonably specificity, whereupon, unless Landlord has agreed in writing, in its sole and absolute discretion, to waive such diminution, Tenant, by written notice to Landlord delivered within 10 days after receipt of Landlord’s notice, shall have the right to terminate this Lease effective 10 days after the date of such termination notice.

	
3.

	
Suite 255 and 270 Early Entry.  Provided Tenant has delivered the prepaid Base Rent, the Security Deposit, and insurance certificates (pursuant to Section 10.3 of this Lease), Tenant shall be permitted to occupy Suite 255 and Suite 270 prior to the Suite 255 and Suite 270 Commencement Date (i) at any time after the date hereof for purposes of installing telecommunications and data cabling and (ii) after Suite 255 and Suite 270 are Ready for Occupancy (as defined in Exhibit B-1), for purposes of performing improvements or installing furniture, equipment or other personal property and for the Permitted Use.  Other than the obligation with respect to Suite 255 and 270 to pay Base Rent and Tenant’s Share of any Expense Excess or Tax Excess, all of Tenant’s obligations hereunder shall apply during any period of such early entry.  Notwithstanding the foregoing, Landlord may limit, suspend or terminate Tenant’s rights to enter Suite 255 and Suite 270 pursuant to this Section 3 if Landlord reasonably determines that such entry is endangering individuals working in Suite 255 and Suite 270 or is delaying completion of the Tenant Improvement Work in Suite 255 and/or Suite 270 pursuant to Exhibit B-1 hereto.  Notwithstanding the foregoing, if Suite 255 and Suite 270 are  not Ready for Occupancy  on or before the Outside Completion Date (defined below), Tenant, as its sole remedy, shall be entitled to an abatement of Base Rent with respect to Suite 255 and Suite 270, beginning on the date that Base Rent for Suite 255 and Suite 270 otherwise first becomes payable hereunder, in the amount of $871.66 for each day in the period beginning on the Outside Completion Date and ending on the date immediately preceding the date Suite 255 and Suite 270 become Ready for Occupancy.  As used herein, “Outside Completion Date” means the August 22, 2011; provided, however, that the Outside Completion Date shall be postponed by one (1) day for each day, if any, by which the substantial completion of the Tenant Improvement Work for Suite 255 and Suite 270 is delayed by (a) any event of Force Majeure, or (b) any change to the scope of the Tenant Improvement Work from that described in Section 2.1 of Exhibit B-1.

	
4.

	
Suite 350 Early Entry.  Provided Tenant has delivered the prepaid Base Rent, the Security Deposit, and insurance certificates (pursuant to Section 10.3 of this Lease), Tenant may enter Suite 350 prior to the Suite 350 Commencement Date solely for the purpose of installing telecommunications and data cabling, equipment, furnishings and other personal property in Suite 350. Other than the obligation with respect to Suite 350 to pay Base Rent and Tenant’s Share of any Expense Excess or Tax Excess, all of Tenant’s obligations hereunder shall apply during any period of such early entry.

	
5. 

	
Extension Option.

	
  

	
5.1.

	
Grant of Option; Conditions.  Tenant shall have the right (the “Extension Option”) to extend the Term for one additional period of three (3) years commencing on the day following the Expiration Date and ending on the third anniversary of the Expiration Date (the “Extension Term”), if:

	
  

	
A.

	
Not less than 12 and not more than 15 full calendar months before the Expiration Date, Tenant delivers written notice to Landlord (the “Extension Notice”) electing to exercise the Extension Option and stating Tenant’s estimate of the Prevailing Market (defined in Section 5.5 below) rate for the Extension Term;

	
  

	
B.

	
Tenant is not in default under the Lease beyond any applicable cure period when Tenant delivers the Extension Notice;

	
  

	
C.

	
No more than 25% of the Premises is sublet when Tenant delivers the Extension Notice; and

	
  

	
D.

	
The Lease has not been assigned before Tenant delivers the Extension Notice.

Exhibit F

2

  

	
  

	
5.2.

	
Terms Applicable to Extension Term.

	
  

	
A.

	
During the Extension Term, (a) the Base Rent rate per rentable square foot shall be equal to the Prevailing Market rate per rentable square foot; (b) Base Rent shall increase, if at all, in accordance with the increases assumed in the determination of Prevailing Market rate; and (c) Base Rent shall be payable in monthly installments in accordance with the terms and conditions of the Lease.

	
  

	
B.

	
During the Extension Term Tenant shall pay Tenant’s Share of Expenses and Taxes for the Premises in accordance with the Lease.

	
  

	
5.3.

	
Procedure for Determining Prevailing Market.  Within 30 days after receiving the Extension Notice, Landlord shall give Tenant either (i) written notice (“Landlord’s Binding Notice”) accepting Tenant’s estimate of the Prevailing Market rate for the Extension Term stated in the Extension Notice, or (ii) written notice (“Landlord’s Rejection Notice”) rejecting such estimate and stating Landlord’s estimate of the Prevailing Market rate for the Extension Term.  If Landlord gives Tenant a Landlord’s Rejection Notice, Tenant, within 15 days thereafter, shall give Landlord either (i) written notice (“Tenant’s Binding Notice”) accepting Landlord’s estimate of the Prevailing Market rate for the Extension Term stated in such Landlord’s Rejection Notice, or (ii) written notice (“Tenant’s Rejection Notice”) rejecting such estimate.  If Tenant gives Landlord a Tenant’s Rejection Notice, Landlord and Tenant shall work together in good faith to agree in writing upon the Prevailing Market rate for the Extension Term.  If, within 30 days after delivery of a Tenant’s Rejection Notice, the parties fail to agree in writing upon the Prevailing Market rate, Tenant’s Extension Option shall be of no further force or effect.

	
  

	
5.4.

	
Extension Amendment.  If Tenant is entitled to and properly exercises its Extension Option, and if the Prevailing Market rate for the Extension Term is determined in accordance with Section 5.3 above, Landlord, within a reasonable time thereafter, shall prepare and deliver to Tenant an amendment (the “Extension Amendment”) reflecting changes in the Base Rent, the Term, the Expiration Date, and other appropriate terms, and Tenant shall execute and return the Extension Amendment to Landlord within 15 days after receiving it.  Notwithstanding the foregoing, upon determination of the Prevailing Market rate for the Extension Term in accordance with Section 5.3 above, an otherwise valid exercise of the Extension Option shall be fully effective whether or not the Extension Amendment is executed.

	
  

	
5.5.

	
Definition of Prevailing Market. For purposes of this Extension Option, “Prevailing Market” shall mean the arms-length, fair-market, annual rental rate per rentable square foot under extension and renewal leases and amendments entered into on or about the date on which the Prevailing Market is being determined hereunder for space comparable to the Premises in the Building and office buildings comparable to the Building in the Larkspur, California area.  The determination of Prevailing Market shall take into account any material economic differences between the terms of the Lease and any comparison lease or amendment, such as rent abatements, construction costs and other concessions, and the manner, if any, in which the landlord under any such lease is reimbursed for operating expenses and taxes.  The determination of Prevailing Market shall also take into consideration any reasonably anticipated changes in the Prevailing Market rate from the time such Prevailing Market rate is being determined and the time such Prevailing Market rate will become effective under the Lease.

 

	
  

	
5.6.

	
Subordination.  Notwithstanding anything herein to the contrary, Tenant’s Extension Option is subject and subordinate to the expansion rights (whether such rights are designated as a right of first offer, right of first refusal, expansion option or otherwise) of any tenant of the Building or the Project existing on the date hereof.

	
6. 

	
Rooftop Space.

	
  

	
6.1.

	
Subject to the terms of this Section 6 , during the Term (and any extension thereof, if any), Tenant may use the Roof Space (defined below) for the purpose of installing, operating, maintaining and removing an approximate 12- inch Dish/Antenna or other communication device approved by the Landlord (the “Dish/Antenna”).  As used herein, “Roof Space” means space on the roof of the Building, not exceeding four (4) square feet in size, and otherwise reasonably designated by Landlord.  Landlord may relocate the Roof Space from time to time as reasonably necessary during the Term (and any extension thereof, if any); provided, however, such new location shall not negatively impact the effectiveness of the Dish/Antenna in any material manner.

Exhibit F

3

  

	
  

	
6.2.

	
Tenant’s design and installation of the Dish/Antenna shall be subject to Sections 7.2 and 7.3 of this Lease as if the Dish/Antenna were being installed in the Premises.  Without limiting the foregoing, Landlord shall have the right to approve Tenant’s plans and specifications for the Dish/Antenna, the manner in which the Dish/Antenna is attached to the roof of the Building, and the manner in which any cables are run to and from the Dish/Antenna.  Tenant shall be responsible for obtaining all necessary governmental and regulatory approvals and for the cost of installing, operating, maintaining and removing the Dish/Antenna.  The Dish/Antenna shall be tagged with weatherproof labels showing manufacturer, model, frequency range, and Tenant’s name.  All cable connected to the Dish/Antenna (the “Dish/Antenna Cable”) shall be tagged in the telecom closet on each floor with a label showing Tenant’s name, phone number and suite number.  Tenant shall notify Landlord upon completion of the installation of the Dish/Antenna.  If Landlord determines that the Dish/Antenna equipment does not comply with the approved plans and specifications, that the installation was defective, or that the Building has been damaged during installation of the Dish/Antenna, Tenant shall cure such defective condition promptly upon Landlord’s request.  If Tenant fails to promptly perform such cure, Landlord may do so, in which event Tenant shall pay Landlord, upon demand, the reasonable cost of such cure.  If at any time Landlord, in its sole discretion, deems it necessary, Tenant, at its expense, shall provide and install appropriate aesthetic screening, reasonably satisfactory to Landlord, for the Dish/Antenna (the “Aesthetic Screening”).

	
  

	
6.3.

	
Tenant, after reasonable notice to Landlord, may access the roof of the Building and the Roof Space for the purpose of installing, maintaining, repairing and removing the Dish/Antenna, Dish/Antenna Cable, the appurtenances and the Aesthetic Screening, if any (collectively, the “Dish/Antenna Items”).  Notwithstanding the foregoing, only authorized engineers, employees or properly authorized contractors of Tenant, FCC inspectors, or persons under their direct supervision shall have access to the roof of the Building and the Roof Space.  Tenant shall use diligent efforts to minimize the number of people having access to the roof of the Building and the Roof Space and the frequency of their visits.

	
  

	
6.4.

	
Tenant shall ensure that the installation, maintenance, operation and removal of the Dish/Antenna Items does not damage, or unreasonably interfere with Landlord’s or any other occupant’s use of, the Building or its roof.  Notwithstanding Sections 7 and 10.4 of this Lease, Tenant shall be responsible for any damage caused to the roof or any other part of the Building that may be caused by Tenant or any of its agents or representatives in exercising Tenant’s rights or performing Tenant’s obligations under this Section 6.  For purposes of Sections 5, 7 and 10 of this Lease, the Roof Space shall be deemed part of the Premises.

	
  

	
6.5.

	
Tenant shall install only equipment of types and frequencies that will not unreasonably interfere with Landlord or existing tenants of the Building.  If Tenant’s equipment causes such interference, Tenant shall change the frequency on which it transmits and/or receives and take any other steps necessary to eliminate the interference.  If, in Landlord’s reasonable judgment, such interference cannot be eliminated within a reasonable period of time, Tenant shall remove the Dish/Antenna from the Roof Space and remove such other Dish/Antenna Items as Landlord may request.

	
  

	
6.6.

	
Tenant, at its expense, shall install, operate and maintain the Dish/Antenna Items in a good and workmanlike manner, and in compliance with all Building, electric, communication, and safety codes, ordinances, standards, regulations and requirements, now in effect or hereafter promulgated, of the Federal Government, including the Federal Communications Commission (the “FCC”), the Federal Aviation Administration (“FAA”) or any successor agency of either the FCC or FAA having jurisdiction over radio or telecommunications, and of the state, city and county in which the Building is located.  No Landlord Party shall be responsible for any licensing, operation or maintenance of Tenant’s equipment.  Tenant shall be responsible for performing any obligations under its FCC license.  The Dish/Antenna shall be connected to Landlord’s power supply in strict compliance with all applicable Building, electrical, fire and safety codes.  No Landlord Party shall be liable for any stoppage or shortage of electrical power furnished to the Dish/Antenna or the Roof Space because of (i) any act, omission or requirement of the public utility serving the Building, (ii) any act or omission of any other tenant, invitee or licensee or their respective agents, employees or contractors, or (iii) any other cause beyond Landlord’s reasonable control, and Tenant shall not be entitled to any rental abatement for any such stoppage or shortage of electrical power.  No Landlord Party shall have any liability for the conduct or safety of any of Tenant’s representatives, repair, maintenance and engineering personnel while in or on any part of the Building or the Roof Space.

Exhibit F

4

  

	
  

	
6.7.

	
The Dish/Antenna Items shall remain the personal property of Tenant, and shall be removed by Tenant at its own expense at the expiration or earlier termination of this Lease or Tenant’s right to possession hereunder.  Tenant shall repair any damage caused by such removal, including by patching any holes to match, as closely as possible, the color surrounding the area where the equipment and appurtenances were attached.  Tenant shall maintain the Dish/Antenna Items in a safe and aesthetically satisfactory condition, as reasonably determined by Landlord, and in good operating condition.  Tenant shall keep the roof of the Building and the Roof Space free of all trash or waste materials produced by Tenant or Tenant’s agents, employees or contractors.

	
  

	
6.8.

	
Before commencing any installation, operation, repair or removal of the Dish/Antenna Items, Tenant shall (a) obtain Landlord’s reasonable approval of the service provider retained to perform such work for Tenant, and (b) notify Landlord of such work and coordinate such work with Landlord in order to avoid impairing any warranties relating to the roof.  For the performance of any such work affecting the roof, Tenant, upon Landlord’s request, shall, at Tenant’s expense, retain (or cause its contractor to retain) any contractor having a then existing warranty in effect relating to the roof.  Except in an emergency, Landlord shall notify Tenant 30 days before commencing any roof repairs that could interrupt Tenant’s telecommunication service or otherwise adversely affect Tenant’s Dish/Antenna.

	
  

	
6.9.

	
Tenant shall not allow any provider of telecommunication, video, data or related services (“Communication Services”) to locate any equipment on the roof of the Building or in the Roof Space for any purpose, nor may Tenant use the Roof Space and/or Dish/Antenna to provide Communication Services to an unaffiliated tenant, occupant or licensee of another building, or to facilitate the provision of Communication Services on behalf of another Communication Services provider to an unaffiliated tenant, occupant or licensee of the Building or any other building.

	
  

	
6.10.

	
If a Default occurs as a result of any failure by Tenant to perform any obligation under this Section 6, Landlord, without limiting any other rights or remedies, may remove all or any of the Dish/Antenna Items and restore the Building and the Roof Space to the conditions existing before the Dish/Antenna Items were installed, in which event Tenant shall reimburse Landlord, upon demand, for all reasonable expenses of such removal and restoration.

	
  

	
6.11.

	
Tenant’s rights under this Section 6 may not be transferred to any other party except in connection with a Transfer permitted under this Lease.  If Landlord establishes a standard license agreement with respect to the use of roof space by tenants of the Building, Tenant, upon Landlord’s request, shall enter into such license agreement with Landlord provided that such license agreement does not materially reduce Tenant’s rights or increase Tenant’s obligations under this Section 6.

Exhibit F

5

  

EXHIBIT G

 

LARKSPUR LANDING OFFICE PARK

LARKSPUR LANDING BUILDING 1100

LARKSPUR, CALIFORNIA

 

ASBESTOS NOTIFICATION

 

Asbestos-containing materials (“ACMs”) were historically commonly used in the construction of commercial buildings across the country.  ACMs were commonly used because of their beneficial qualities; ACMs are fire-resistant and provide good noise and temperature insulation.

 

Some common types of ACMs include surfacing materials (such as spray-on fireproofing, stucco, plaster and textured paint), flooring materials (such as vinyl floor tile and vinyl floor sheeting) and their associated mastics, carpet mastic, thermal system insulation (such as pipe or duct wrap, boiler wrap and cooling tower insulation), roofing materials, drywall, drywall joint tape and drywall joint compound, acoustic ceiling tiles, transite board, base cove and associated mastic, caulking, window glazing and fire doors.  These materials are not required under law to be removed from any building (except prior to demolition and certain renovation projects).  Moreover, ACMs generally are not thought to present a threat to human health unless they cause a release of asbestos fibers into the air, which does not typically occur unless (1) the ACMs are in a deteriorated condition, or (2) the ACMs have been significantly disturbed (such as through abrasive cleaning, or maintenance or renovation activities).

 

It is possible that some of the various types of ACMs noted above (or other types) are present at various locations in the Building.  Anyone who finds any such materials in the Building should assume them to contain asbestos unless those materials are properly tested and found to be otherwise.  In addition, under applicable law, certain of these materials are required to be presumed to contain asbestos in the Building because the Building was built prior to 1981 (these materials are typically referred to as “Presumed Asbestos Containing Materials” or “PACM”).  PACM consists of thermal system insulation and surfacing material found in buildings constructed prior to 1981, and asphalt or vinyl flooring installed prior to 1981.  If any thermal system insulation, asphalt or vinyl flooring or surfacing materials are found to be present in the Building, such materials must be considered PACM unless properly tested and found otherwise.  In addition, Landlord has identified the presence of certain ACMs in the Building.  For information about the specific types and locations of these identified ACMs, please contact the Building manager.  The Building Manager maintains records of the Building’s asbestos information including any Building asbestos surveys, sampling and abatement reports.  This information is maintained as part of Landlord’s asbestos Operations and Maintenance Plan (“O&M Plan”).

 

The O&M Plan is designed to minimize the potential of any harmful asbestos exposure to any person in the Building. Because Landlord is not a physician, scientist or industrial hygienist, Landlord has no special knowledge of the health impact of exposure to asbestos.  Therefore, Landlord hired an independent environmental consulting firm to prepare the Building’s O&M Plan.  The O&M Plan includes a schedule of actions to be taken in order to (1) maintain any building ACMs in good condition, and (2) to prevent any significant disturbance of such ACMs.  Appropriate Landlord personnel receive regular periodic training on how to properly administer the O&M Plan.

 

The O&M Plan describes the risks associated with asbestos exposure and how to prevent such exposure.  The O&M Plan describes those risks, in general, as follows:  asbestos is not a significant health concern unless asbestos fibers are released and inhaled.  If inhaled, asbestos fibers can accumulate in the lungs and, as exposure increases, the risk of disease (such as asbestosis and cancer) increases.  However, measures taken to minimize exposure and consequently minimize the accumulation of fibers, can reduce the risk of adverse health effects.

 

The O&M Plan also describes a number of activities which should be avoided in order to prevent a release of asbestos fibers.  In particular, some of the activities which may present a health risk (because those activities may cause an airborne release of asbestos fibers) include moving, drilling, boring or otherwise disturbing ACMs.  Consequently, such activities should not be attempted by any person not qualified to handle ACMs.  In other words, the approval of Building management must be obtained prior to engaging in any such activities.  Please contact the Building manager for more information in this regard.  A copy of the written O&M Plan for the Building is located in the Building Management Office and, upon your request, will be made available to tenants for you to review and copy during regular business hours.

 

Because of the presence of ACM in the Building, we are also providing the following warning, which is commonly known as a California Proposition 65 warning:  WARNING:  This building contains asbestos, a chemical known to the State of California to cause cancer.

Please contact the Building manager with any questions regarding the contents of this Exhibit G.

Exhibit G

1

  

EXHIBIT H

 

LARKSPUR LANDING OFFICE PARK

LARKSPUR LANDING BUILDING 1100

LARKSPUR, CALIFORNIA

 

GUARANTY OF LEASE

FOR VALUE RECEIVED and in consideration for and as an inducement to CA-LARKSPUR LANDING OFFICE PARK LIMITED PARTNERSHIP, a Delaware limited partnership ("Landlord") to lease certain real property to DIGITAL DOMAIN PRODUCTIONS, INC., a Delaware corporation, as tenant ("Tenant"), pursuant to a lease dated ________, 2011 (the “Lease") by and between Landlord and Tenant, the undersigned, DIGITAL DOMAIN MEDIA GROUP, INC., a Florida corporation (“Guarantor”) does hereby unconditionally and irrevocably guarantee to Landlord the punctual payment of all Rent (as such term is defined in the Lease) payable by Tenant under the Lease throughout the term of the Lease and any and all renewals and extensions thereof in accordance with and subject to the provisions of the Lease, and the full performance and observance of all other terms, covenants, conditions and agreements therein provided to be performed and observed by Tenant under the terms of the Lease, for which the undersigned shall be jointly and severally liable with Tenant.  If any default on the part of Tenant shall occur under the Lease, the undersigned does hereby covenant and agree to pay to Landlord upon demand in each and every instance such sum or sums of money and to perform each and every covenant, condition and agreement under the Lease as Tenant is and shall become liable for or obligated to pay or perform under the Lease, together with the costs reasonably incurred by Landlord in connection therewith, including, without limitation, reasonable attorneys' fees.  Such payments of Rent and other sums shall be made monthly or at such other intervals as the same shall or may become payable under the Lease, including any accelerations thereof, all without requiring any notice from Landlord (other than any notice required by the Lease) of such non-payment or non performance, all of which the undersigned hereby expressly waives.

The maintenance of any action or proceeding by Landlord to recover any sum or sums that may be or become due under the Lease and to secure the performance of any of the other terms, covenants and conditions of the Lease shall not preclude Landlord from thereafter instituting and maintaining subsequent actions or proceedings for any subsequent default or defaults of Tenant under the Lease.  The undersigned does hereby consent that without affecting the liability of the undersigned under this Guaranty and without notice to the undersigned, time may be given by Landlord to Tenant for payment of Rent and such other sums and performance of said other terms, covenants and conditions, or any of them, and such time extended and indulgence granted, from time to time, or Tenant may be dispossessed or Landlord may avail itself of or exercise any or all of the rights and remedies against Tenant provided by law or by the Lease, and may proceed either against Tenant alone or jointly against Tenant and the undersigned or against the undersigned alone without first prosecuting or exhausting any remedy or claim against Tenant.  The undersigned does hereby further consent to any subsequent change, modification or amendment of the Lease in any of its terms, covenants or conditions, or in the Rent payable thereunder, or in the premises demised thereby, or in the term thereof, and to any assignment or assignments of the Lease, and to any subletting or sublettings of the premises demised by the Lease, and to any renewals or extensions thereof, all of which may be made without notice to or consent of the undersigned and without in any manner releasing or relieving the undersigned from liability under this Guaranty.

The undersigned does hereby agree that the bankruptcy of Tenant shall have no effect on the obligations of the undersigned hereunder.  The undersigned does hereby further agree that in respect of any payments made by the undersigned hereunder, the undersigned shall not have any rights based on suretyship, subrogation or otherwise to stand in the place of Landlord so as to compete with Landlord as a creditor of Tenant, unless and until all claims of Landlord under the Lease shall have been fully paid and satisfied.

The undersigned hereby waives and agrees not to assert:  (a) any right to require Landlord to proceed against Tenant, or any other guarantor or person or to pursue any other security or remedy before proceeding against the undersigned; (b) any defense based on the validity or enforceability of the Lease; (c) any right or defense that may arise by reason of the incapacity, lack of authority, death or disability of Tenant or any other person; and (d) any right or defense arising by reason of the absence, impairment, modification, limitation, destruction or cessation (in bankruptcy, by an election of remedies, or otherwise) of the liability of Tenant of the subrogation rights of the undersigned or of the right of the undersigned to proceed against Tenant for reimbursement.  The undersigned waives any right, statutory, or otherwise, for itself to require or for Tenant to require Landlord to apply rents received toward the obligations of the undersigned under this Guaranty, or to otherwise prioritize the receipt of rents as against the obligations of the undersigned under this Guaranty.  The undersigned hereby waives and agrees not to assert (x) any right or defense  based on the absence of any or all presentments, demands (including demands for performance), notices (including notices of any adverse change in the financial status of Tenant, notices of any other facts which increase the risk to the undersigned, notices of non-performance and notices of acceptance of this Guaranty) and protests of each and every kind; (y) the defense of any statute of limitations in any action under or related to this Guaranty or the Lease; and (z) any right or defense based on a lack of diligence or failure or delay by Landlord in enforcing its rights under this Guaranty or the Lease.  The undersigned hereby waives and agrees not to assert or take advantage of any right to (i) exoneration if Landlord’s actions shall impair any security or collateral of the undersigned; (ii) any security or collateral held by Landlord; (iii) require Landlord to proceed against or exhaust any security or collateral before proceeding against the undersigned; and (iv) require Landlord to pursue any right or remedy for the benefit of the undersigned.  Without limiting the generality of any of the covenants and agreements of the undersigned set forth in this Guaranty, the undersigned hereby waives any and all benefits of the second sentence of Section 2822(a) and the provisions of Sections 2809, 2810, 2819, 2822, 2845, 2848, 2849 and 2850 of the California Civil Code and any similar or analogous statutes of California or any jurisdiction.

Exhibit H

1

  

Until all the Tenant’s obligations under the Lease are fully performed, the undersigned (a) shall have no right of subrogation or reimbursement against the Tenant by reason of any payments or acts of performance by the undersigned under this Guaranty, (b) subordinates any liability or indebtedness of the Tenant now or hereafter held by the undersigned to the obligations of the Tenant under, arising out of or related to the Lease or Tenant’s use of the Premises; and (c) acknowledges that the actions of Landlord may affect or eliminate any rights of subrogation or reimbursement of the undersigned as against Tenant without any liability or recourse against Landlord.

Neither this Guaranty nor any of the provisions hereof can be modified, waived or terminated, except by a written instrument signed by Landlord.  The provisions of this Guaranty shall apply to, bind and inure to the benefit of the undersigned and Landlord and their respective heirs, legal representatives, successors and assigns.  As used herein, the term “Tenant” means the Tenant specifically named in the Lease and also any assignee or subtenant of said Lease and any successor to the interests of said Tenant, assignee or sublessee of such Lease or any part thereof, whether by assignment, sublease or otherwise including, without limitation, any trustee in bankruptcy and any bankruptcy estate of Tenant, Tenant’s assignee or sublessee.  The undersigned, if there be more than one, shall be jointly and severally liable hereunder, and for purposes of such several liability the word "undersigned" wherever used herein shall be construed to refer to each of the undersigned parties separately, all in the same manner and with the same effect as if each of them had signed separate instruments, and this Guaranty shall not be revoked or impaired as to any of such parties by the death of another party or by revocation or release of any obligations hereunder of any other party.  If the undersigned is a corporation, each individual executing this Guaranty on behalf of said corporation represents and warrants that he is duly authorized to execute and deliver this Guaranty on behalf of said corporation, in accordance with a duly adopted resolution of the Board of Directors of said corporation or in accordance with the by-laws of said corporation, and that this Guaranty is binding upon said corporation in accordance with its terms.

If Landlord should retain counsel and/or institute any suit against Guarantor to enforce this Guaranty or any covenants or obligations hereunder, then Guarantor shall pay to Landlord, upon demand, all reasonable attorneys’ fees, costs and expenses, including, without limitation, court costs, filing fees, recording costs, and all other costs and expenses incurred in connection therewith (all of which are referred to herein as “Enforcement Costs”), in addition to all other amounts due hereunder.  This Guaranty shall be governed by and construed in accordance with the internal laws of the state where the premises demised by the Lease are located.  For the purpose solely of litigating any dispute under this Guaranty, the undersigned submits to the jurisdiction of the courts of said state.  The undersigned hereby waives any right to trial by jury and further waives and agrees not to assert or take advantage of any defense based on the claim that any arbitration decision binding upon Landlord or Tenant is not binding on the undersigned.

Any notice or other communication to be given to Landlord or the undersigned hereunder shall be in writing and sent in accordance with the notice provisions of the Lease.  Notices to Landlord shall be delivered to Landlord’s address set forth in the Lease.  Notices to the undersigned shall be addressed as follows:  __________________________________.  In the event Guarantor’s notice address as set forth above changes, Guarantor agrees to provide written notice to Landlord of such change in address.  If Guarantor’s notice address is not filled in at the above blank, or if the Guarantor’s notice address is a post office box address, then, for all purposes under this Guaranty, Landlord may send all notices under this Guaranty to Guarantor, c/o Tenant, at the same notice address Landlord uses for the Tenant under the Lease, and any notice delivered in accordance with the foregoing shall be deemed to have been properly delivered to Guarantor.

IN WITNESS WHEREOF, the undersigned has executed this Guaranty as of the date of the Lease.

Exhibit H

2

  

	
GUARANTOR:

	  
	
DIGITAL DOMAIN MEDIA GROUP, INC., a Florida corporation

	  
	
By:

	
      

	
Name:  

	
      

	
Title:

	
      

	  	  
	
By:

	
      

	
Name:

	
      

	
Title:

	
      

Exhibit H

3EXHIBIT 10.55

 

STOCK PURCHASE AGREEMENT

 

THIS STOCK PURCHASE AGREEMENT (the “Agreement”) is made as of _______, 2011, by and between Digital Domain Institute, Inc. (the “Company”), a corporation organized under the laws of the State of Florida, with its principal offices at 8881 South US Highway One, Port St. Lucie, FL 34952, and the purchaser whose name and address is set forth on the signature pages hereto (the “Purchaser”).

 

IN CONSIDERATION of the mutual covenants contained in this Agreement, the Company and the Purchaser agree as follows:

 

SECTION 1.  Authorization of Sale of the Shares.  Subject to the terms and conditions of this Agreement, the Company has authorized the issuance and sale in a private placement of up to 4,500,000 shares (the “Shares”) of common stock, no par value per share (the “Common Stock”), of the Company.  The Company reserves the right to increase or decrease the number of Shares sold in this private placement prior to the Closing Date (as defined below) for the purpose of including therein the Other Purchasers (as defined below), if any.

 

SECTION 2.  Agreement to Sell and Purchase the Shares.  At the Closing (as defined below), the Company will, subject to the terms and conditions of this Agreement, issue and sell to the Purchaser, and the Purchaser will buy from the Company, upon the terms and conditions hereinafter set forth, the number of Shares set forth on the signature pages hereto, for an aggregate purchase price equal to the number of such Shares multiplied by a per-share purchase price of US $8.00.

 

The Company may, in its sole and absolute discretion, enter into the same form of purchase agreement with certain other investors (the “Other Purchasers”) and may, in its sole and absolute discretion, complete sales of additional Shares to them. The Purchaser and such Other Purchasers, if any, are hereinafter sometimes collectively referred to as the “Purchasers,” and this Agreement and the stock purchase agreements executed by such Other Purchasers, if any, are hereinafter sometimes collectively referred to as the “Agreements.”

 

SECTION 3.  Delivery of the Shares at the Closing.  The completion of the purchase and sale of the Shares (the “Purchaser Shares”) referenced in the first paragraph of Section 2 hereof (the “Closing”) shall occur as soon as practicable at such place within the jurisdiction referenced in Section 5.7 as agreed to by the parties hereto, on the date of and concurrently with the execution of this Agreement, or on such later date or at such different location as the parties shall agree in writing, but not prior to the date that the conditions for Closing set forth below have been satisfied or waived by the appropriate party (the “Closing Date”).

  

1

  

At the Closing, the Company shall deliver to the Purchaser one or more stock certificates registered in the name of the Purchaser, or, if so indicated on the Stock Certificate Questionnaire attached hereto as Appendix I, in such nominee name(s) as designated by the Purchaser, representing the number of Shares set forth on the signature pages hereto, each bearing an appropriate legend referring to the fact that the Purchaser Shares were sold in reliance upon the exemption from the registration requirements of the Securities Act of 1933, as amended (the “Securities Act”) provided by Section 4(2) thereof and Rule 506 thereunder.  The name or names in which the stock certificates are to be registered are set forth in the Stock Certificate Questionnaire attached hereto as Appendix I.  The Company’s obligation to complete the purchase and sale of the Purchaser Shares and deliver such stock certificate(s) to the Purchaser at the Closing shall be subject to the following conditions, any one or more of which may be waived by the Company:  (a) receipt by the Company of same-day funds in the full amount of the purchase price for the Purchaser Shares being purchased hereunder; and (b) the accuracy in all material respects of the representations and warranties made by the Purchaser in Section 5.8 hereof, and the accuracy of all other representations and warranties made herein by the Purchaser (in each case, as if such representations and warranties were made on the Closing Date), and the fulfillment in all material respects of those undertakings made herein by the Purchaser to be fulfilled prior to the Closing.  The Purchaser’s obligation to accept delivery of such stock certificate(s) and to pay for the Purchaser Shares evidenced thereby shall be subject to the following conditions, any one or more of which may be waived by the Purchaser:

 

(a) each of the representations and warranties of the Company made herein which is qualified by materiality or material adverse effect or words of similar effect shall be accurate in all respects as of the Closing Date (except to the extent any such representations and warranties expressly relate to a specific date, in which case such representations and warranties shall be accurate as of such date), and each of the representations and warranties of the Company made herein which is not so qualified shall be accurate in all material respects as of the Closing Date (except to the extent such representations and warranties expressly relate to a specific date, in which case such representations and warranties shall be accurate in all material respects  as of such date); and

 

(b) the fulfillment in all material respects of those undertakings made herein by the Company to be fulfilled prior to the Closing.

 

The Purchaser’s obligations hereunder are expressly not conditioned on the purchase by any or all of the Other Purchasers, if any, of the Shares that they have agreed to purchase from the Company.

 

SECTION 4.  Representations, Warranties and Covenants of the Company.  The Company hereby represents and warrants to, and covenants with, the Purchaser as follows:

 

4.1     Organization; Good Standing. The Company is duly organized, validly existing and in good standing under the laws of its jurisdictions of incorporation.  The Company is duly qualified to do business and is in good standing as a foreign corporation in each jurisdiction in which the nature of the business conducted by it or location of the assets or properties owned, leased or licensed by it requires such qualification, except for such jurisdictions where the failure to so qualify individually or in the aggregate would not have a material adverse effect on the assets, properties, condition, financial or otherwise, or in the results of operations, business affairs or business prospects of the Company considered as a whole (a “Material Adverse Effect”); and to the Company’s best knowledge and belief having made all reasonable enquiries, no proceeding has been instituted, threatened, pending, foreseeable or possible in any such jurisdiction revoking, limiting or curtailing, or seeking to revoke, limit or curtail, such power and authority or qualification.

  

2

  

4.2     Capitalization. As of the date immediately prior to the commencement of the sale of the Shares, the authorized capital stock of the Company consists of 100,000,000 shares of Common Stock, no par value per share.  As of the date hereof: (i) 18,750,000 shares of Common Stock are issued and outstanding, and except as set forth in this Section 4.2, there are no other options, warrants or other rights to purchase from the Company any shares of its capital stock other than pursuant to the Agreements.  The certificates evidencing the Purchaser Shares are in due and proper legal form and have been duly authorized for issuance by the Company.  All of the issued and outstanding shares of Common Stock have been duly and validly issued and are fully paid and nonassessable.  There are no statutory preemptive or other similar rights to subscribe for or to purchase or acquire any shares of Common Stock of the Company, or any such rights pursuant to its Articles of Incorporation or bylaws, or equivalent formation and governance documents, or any agreement or instrument to or by which the Company is a party or bound, in each case that are triggered by the purchase and sale transaction contemplated by this Agreement, except for any such rights under any such agreement or instrument that have been waived prior to the date hereof.  The Purchaser Shares, when issued and delivered and paid for as provided herein, will be duly and validly issued and will be fully paid and nonassessable and will be issued free and clear of any security interests, liens, encumbrances, equities, restrictions on transfer (other than as arising under applicable securities laws or this Agreement), third party rights or claims. The Purchaser Shares will be issued in compliance with all applicable federal and state securities laws.

 

4.3     Due Authorization.  This Agreement has been duly authorized, executed and delivered by the Company and, assuming execution and delivery by each of the other parties thereto, constitutes the legal, valid and binding obligation of the Company, enforceable in accordance with its terms, except as such enforceability may be limited by applicable bankruptcy, insolvency, reorganization, moratorium or other laws of general application relating to the enforcement of creditor’s rights and the application of equitable principles relating to the availability of remedies, and except as rights to indemnity or contribution may be limited by federal or state securities laws or the public policy underlying such laws.  All necessary corporate action has been duly and validly taken by the Company to authorize the execution, delivery and performance of this Agreement and the issuance and sale of the Shares by the Company.

 

4.4     No Default or Consents.  Neither the execution, delivery and performance of this Agreement by the Company nor the consummation by the Company of any of the transactions contemplated hereby (including, without limitation, the issuance and sale by the Company of the Shares) will give rise to a right to terminate or accelerate the due date of any payment due under, or conflict with or result in the breach of any term or provision of, or constitute a default (or an event which with notice or lapse of time or both would constitute a default) under, or require any consent or waiver under, or result in the execution or imposition of any lien, charge or encumbrance upon any properties or assets of the Company pursuant to the terms of, any indenture, mortgage, deed of trust or other agreement or instrument to which the Company is a party or by which the Company is bound, or any franchise, license, permit, judgment, decree, order, statute, rule or regulation applicable to the Company or violate any provision of the charter or bylaws, or equivalent formation and governance documents, of the Company, except for such consents or waivers which have already been obtained and are in full force and effect.

  

3

  

4.5     Permits. The Company has all requisite corporate power and authority, and all necessary authorizations, approvals, consents, orders, licenses, certificates and permits of and from all governmental or regulatory bodies or any other person or entity (collectively, the “Permits”), to own, lease and license its assets and properties and conduct its business, all of which are valid and in full force and effect, except where the lack of such Permits, individually or in the aggregate, would not have a Material Adverse Effect. The Company has fulfilled and performed in all material respects all of its material obligations with respect to such Permits and no event has occurred that allows, or after notice or lapse of time would allow, revocation or termination thereof or results in any other material impairment of the rights of the Company thereunder.  Except as may be required as to the Company under the Securities Act and state Blue Sky laws, no other Permits are required to enter into, deliver and perform this Agreement and to issue and sell the Purchaser Shares to the Purchaser.

 

4.6     Real and Personal Property.  The Company has good and marketable title in fee simple to all real property, and good and marketable title to all other property, owned by it, in each case free and clear of all liens, encumbrances, claims, security interests and defects, except such as (i) secure the indebtedness of the Company or its parent company, or (ii) do not materially affect the value of such property and do not materially interfere with the use made or proposed to be made of such property by the Company.  All property held under lease by the Company is held under valid, existing and enforceable leases, free and clear of all liens, encumbrances, claims, security interests and defects, except such as (i) secure any Company indebtedness, or (ii) have arisen in the ordinary course of business of the Company and do not materially interfere with the use made or proposed to be made of such property by the Company.

 

4.7     Material Contracts.  Each contract, document or other agreement which is material to the current business of the Company, taken as a whole (the “Material Contracts”), is in full force and effect and is valid and enforceable by and against the Company in accordance with its terms.  The Company, nor to the Company's best knowledge and belief having made all reasonable enquires, any other party, is in default in the observance or performance of any term or obligation to be performed by it under any such Material Contract.

 

4.8     No Violation.  The Company is not in violation of any term of its charter or bylaws, or equivalent formation and governance documents, or of any franchise, license, permit, judgment, decree, order, statute, rule or regulation, where the consequences of such violation, individually or in the aggregate, would have a Material Adverse Effect.

  

4

  

4.9     Consents and Approvals.  Each approval, consent, order, authorization, designation, declaration or filing of, by or with any regulatory, administrative or other governmental body necessary in connection with the execution and delivery by the Company of this Agreement and the consummation of the transactions herein contemplated required to be obtained or performed by the Company has been so obtained or performed.

 

4.10   Legal Proceedings.  There are no claims, actions, suits, proceedings, arbitrations, complaints, charges, judgments, injunctions or governmental investigations pending, or to the Company’s best knowledge and belief having made all reasonable enquiries threatened, to which Company is a party or of which any property of the Company is the subject which the management of the Company believes will have a Material Adverse Effect.

 

4.11   Taxes.  The Company has timely filed all Federal, state, local and foreign tax returns which are required to be filed through the date hereof, which returns are true and correct in all material respects, or has received timely extensions thereof, and has paid all taxes shown on such returns and all assessments received by it to the extent that the same are material and have become due. There are no tax audits or investigations pending; nor are there any material proposed additional tax assessments against the Company.

 

4.12   Insurance.  All material fire and casualty, general liability, and business interruption insurance policies maintained by the Company are in full force and effect, are with reputable insurance carriers, provide full and adequate coverage for all normal risks incident to the business of the Company, and are in character and amount at least reasonably equivalent to that carried by persons engaged in similar businesses and subject to the same or similar perils or hazards, except for any such failures to maintain insurance policies that, individually or in the aggregate, are not reasonably likely to have a Material Adverse Effect.

 

4.13   Environmental Laws.  (i) The Company is in compliance in all material respects with all applicable rules, laws and regulation relating to the use, treatment, release, storage or disposal of hazardous or toxic substances or pollution or the protection of employee health or safety, public health or the environment (“Environmental Laws”); (ii) the Company has received no notice from any governmental authority or third party of an asserted claim under Environmental Laws; (iii) the Company  has received all permits, licenses or other approvals required of it under Environmental Laws to conduct its business and is in compliance with all material terms and conditions of any such permit, license or approval; (iv) to the Company’s best knowledge and belief having made all reasonable enquiries, no facts currently exist that will require the Company to make future material capital expenditures to comply with Environmental Laws; and (v) no property which is or has been owned, leased or occupied by the Company has been designated as a Superfund site pursuant to the Comprehensive Environmental Response, Compensation and Liability Act of 1980, as amended (42 U.S.C. Section 9601, et. seq.) (“CERCLA”), or otherwise designated as a contaminated site under applicable state or local law.  The Company  has not been named as a “potentially responsible party” under CERCLA.

  

5

  

4.14   Foreign Transactions Reporting Act.  The operations of the Company are and have been conducted at all times in compliance with applicable financial recordkeeping and reporting requirements of the Currency and Foreign Transactions Reporting Act of 1970, as amended, the money laundering statutes of all jurisdictions, the rules and regulations thereunder and any related or similar rules, regulations or guidelines, issued, administered or enforced by any governmental agency (collectively, the “Money Laundering Laws”), and no action, suit or proceeding by or before any court or governmental agency, authority or body or any arbitrator involving the Company with respect to the Money Laundering Laws is pending, or to the best knowledge and belief of the Company having made all reasonable enquiries, threatened.

 

4.15   OFAC.  Neither the Company nor, to the knowledge of the Company, any director, officer, agent, employee or affiliate of the Company, is currently subject to any U.S. sanctions administered by the Office of Foreign Assets Control of the U.S. Treasury Department (“OFAC”); and the Company will not directly or indirectly use the proceeds of the offering of the Shares, or lend, contribute or otherwise make available such proceeds to any subsidiary, joint venture partner or other person or entity, for the purpose of financing the activities of any person currently subject to any U.S. sanctions administered by OFAC.

 

4.16   ERISA.  The Company has fulfilled its obligations, if any, under the minimum funding standards of Section 302 of the U.S. Employee Retirement Income Security Act of 1974 (“ERISA”) and the regulations and published interpretations thereunder with respect to each "plan" as defined in Section 3(3) of ERISA (and such regulations and published interpretations) in which its employees are eligible to participate and each such plan is in compliance in all material respects with the presently applicable provisions of ERISA and such regulations and published interpretations. No “Reportable Event” (as defined in ERISA) has occurred with respect to any “Pension Plan” (as defined in ERISA) for which the Company has any liability.

 

4.17   Use of Proceeds. The Company intends to use the net proceeds from the sale of the Shares for general working capital and for other corporate purposes.

 

4.18   Investment Company.  The Company is not, and after giving effect to the offering and sale of the Shares and the application of the proceeds thereof as described in Section 4.17, will not be, an “investment company” or an entity “controlled” by an “investment company” within the meaning of the Investment Company Act of 1940, as amended, and the rules and regulations of the Securities and Exchange Commission (the “SEC”) thereunder.

 

4.19   Certain Transactions.  Other than agreements or arrangements relating to (i) compensation, and standard employee benefits generally made available to all employees of the Company, (ii) standard director and officer indemnification on terms approved by the Board of Directors of the Company, and (iii) the purchase of shares of the Company’s capital stock and the issuance of options to purchase shares of the Company’s Common Stock, there are no agreements, understandings or proposed transactions between the Company and any of its officers, directors, consultants or key employees, or any affiliate thereof.

  

6

  

4.20   Voting Rights.  To the Company’s knowledge, no stockholder of the Company has entered into any agreements with respect to the voting of capital shares of the Company.

 

SECTION 5.  Representations, Warranties and Covenants of the Purchaser.  The Purchaser represents and warrants to, and covenants with, the Company that:

 

5.1     Experience.  (i) The Purchaser is knowledgeable, sophisticated and experienced in financial and business matters, and is making, and is qualified to make, decisions with respect to investments in shares representing an investment decision like that involved in the purchase of the Shares, including investments in securities issued by the Company and/or comparable entities, has the ability to bear the economic risks of an investment in the Shares and has had the opportunity to request, receive, review and consider all information it deems relevant in making an informed decision to purchase the Shares; (ii) the Purchaser is acquiring the number of Shares set forth on the signature pages hereto in the ordinary course of its business and for its own account for investment only and with no present intention of distributing any of such Shares and subject to no arrangement or understanding with any other persons regarding the distribution of such Shares; (iii) the Purchaser will not, directly or indirectly, offer, sell, pledge, transfer or otherwise dispose of (or solicit any offers to buy, purchase or otherwise acquire or take a pledge of) any of the Shares, except in compliance with the Securities Act and the rules and regulations thereunder, and any applicable state and foreign securities laws; (iv) the Purchaser has, in connection with its decision to purchase the number of Shares set forth on the signature pages hereto, relied solely upon the representations and warranties of the Company contained in this Agreement; (v) the Purchaser has had an opportunity to discuss this investment with representatives of the Company and ask questions of them; and (vi) the Purchaser meets the monetary threshold requirements of a “Qualified Institutional Buyer”, as such term is defined in Rule 144A promulgated under the Securities Act (for the avoidance of doubt, the Purchaser is not a “Qualified Institutional Buyer”).

 

5.2     Reliance on Exemptions.  The Purchaser understands that the Shares are being offered and sold to it in reliance upon specific exemptions from the registration requirements of the Securities Act, the regulations promulgated thereunder, and state securities laws and that the Company is relying upon the truth and accuracy of, and the Purchaser’s compliance with, the representations, warranties, covenants, agreements, acknowledgments and understandings of the Purchaser set forth herein in order to determine the availability of such exemptions and the eligibility of the Purchaser to acquire the Shares.

  

7

  

5.3     Confidentiality.  The Purchaser understands that the information contained in the materials provided to the Purchaser by the Company and its representatives in connection with the purchase and sale of the Shares is strictly confidential and proprietary to the Company and is being submitted to the Purchaser solely for such Purchaser’s confidential use.  The Purchaser agrees to use the information contained in such materials for the sole purpose of evaluating a possible investment in the Shares and the Purchaser acknowledges that it is prohibited from reproducing or distributing this Agreement or any other materials or other information provided by the Company in connection with the Purchaser’s consideration of its investment in the Company, in whole or in part, or divulging or discussing any of their contents, except to its financial, investment or legal advisors who need to know such contents in connection with the Purchaser’s proposed investment in the Purchaser Shares and who agree in writing to be bound by an equivalent obligation of confidentiality and non-use with respect to such contents.  Further, the Purchaser understands that the existence and nature of all conversations and presentations, if any, regarding the Company and the offering of the Shares must be kept strictly confidential.  In addition, the Purchaser understands that United States securities laws may prohibit any person who has received from an issuer material non-public information from purchasing or selling securities of such issuer or from communicating such information to any other person under circumstances in which it is reasonably foreseeable that such person is likely to purchase or sell securities based on such information.   The foregoing agreements shall not apply to any information that is or becomes publicly available through no fault of the Purchaser, or that the Purchaser is required to disclose pursuant to applicable law, regulation or legal process; provided, however, that if the Purchaser is requested or ordered to disclose any such information pursuant to any court or other government order or any other applicable legal procedure, it shall provide the Company with prompt notice of any such request or order in time sufficient to enable the Company to seek an appropriate protective order.

 

5.4     Investment Decision.  The Purchaser understands that nothing in this Agreement or any other materials presented to the Purchaser in connection with the purchase and sale of the Shares constitutes legal, tax or investment advice.  The Purchaser has consulted such legal, tax and investment advisors as it, in its sole discretion, has deemed necessary or appropriate in connection with its purchase of the Shares.

 

5.5     Risk of Loss.  The Purchaser understands that its investment in the Shares involves a significant degree of risk, including a risk of total loss of the Purchaser’s investment, and the Purchaser has full cognizance of and understands all of the risk factors related to the Purchaser’s purchase of the Shares.  The Purchaser understands that no representation is being made as to the future value of the Common Stock.

 

5.6     Legend.  The Purchaser understands that, until such time as a Registration Statement has been declared effective or the Purchaser Shares may be sold pursuant to Rule 144 under the Securities Act without any restriction as to the number of securities as of a particular date that can then be immediately sold, the Purchaser Shares will bear a restrictive legend in substantially the following form:

  

8

  

“THE SHARES EVIDENCED BY THIS CERTIFICATE HAVE NOT BEEN REGISTERED UNDER THE SECURITIES ACT OF 1933, AS AMENDED (THE “SECURITIES ACT”), OR THE SECURITIES LAWS OF ANY STATE OR OTHER JURISDICTION.  THE SHARES REPRESENTED BY THIS CERTIFICATE ARE SUBJECT TO TRANSFER RESTRICTIONS IN ACCORDANCE WITH THE TERMS OF A STOCK PURCHASE AGREEMENT BETWEEN THE COMPANY AND THE STOCKHOLDER, A COPY OF WHICH IS ON FILE WITH THE COMPANY.  THE SHARES MAY NOT BE OFFERED, SOLD, PLEDGED OR OTHERWISE TRANSFERRED EXCEPT (1) PURSUANT TO AN EXEMPTION FROM REGISTRATION UNDER THE SECURITIES ACT OR (2) PURSUANT TO AN EFFECTIVE REGISTRATION STATEMENT UNDER THE SECURITIES ACT, IN EACH CASE IN ACCORDANCE WITH ALL APPLICABLE STATE SECURITIES LAWS AND THE SECURITIES LAWS OF OTHER JURISDICTIONS, AND IN THE CASE OF A TRANSACTION EXEMPT FROM REGISTRATION, UNLESS THE COMPANY HAS RECEIVED AN OPINION OF COUNSEL REASONABLY SATISFACTORY TO IT THAT SUCH TRANSACTION DOES NOT REQUIRE REGISTRATION UNDER THE SECURITIES ACT AND SUCH OTHER APPLICABLE LAWS.”

 

5.7     Residency.  The Purchaser’s principal executive offices are in the jurisdiction set forth immediately below the Purchaser’s name on the signature pages hereto. All discussions and negotiations between the Company and the Purchaser concerning the transactions contemplated by this Agreement occurred in such jurisdiction, and the Purchaser executed, and delivered to the Company as so executed, this Agreement in such jurisdiction.

 

5.8     Organization; Validity; Enforcements.  The Purchaser further represents and warrants to, and covenants with, the Company that (i) the Purchaser has full right, power, authority and capacity to enter into this Agreement and to consummate the transactions contemplated hereby and has taken all necessary action to authorize the execution, delivery and performance of this Agreement, (ii) the making and performance of this Agreement by the Purchaser and the consummation of the transactions herein contemplated will not violate any provision of the organizational documents of the Purchaser or conflict with, result in the breach or violation of, or constitute, either by itself or upon notice or the passage of time or both, a default under any material agreement, mortgage, deed of trust, lease, franchise, license, indenture, permit or other instrument to which the Purchaser is a party, or any statute or any authorization, judgment, decree, order, rule or regulation of any court or any regulatory body, administrative agency or other governmental agency or body applicable to the Purchaser, (iii) no consent, approval, authorization or other order of any court, regulatory body, administrative agency or other governmental agency or body is required on the part of the Purchaser for the execution and delivery of this Agreement or the consummation of the transactions contemplated by this Agreement, (iv) upon the execution and mutual delivery of this Agreement by the parties hereto, this Agreement shall constitute a legal, valid and binding obligation of the Purchaser, enforceable in accordance with its terms, except as enforceability may be limited by applicable bankruptcy, insolvency, reorganization, moratorium or other laws of general application relating to the enforcement of creditor’s rights and the application of equitable principles relating to the availability of remedies, and except as rights to indemnity or contribution may be limited by federal or state securities laws or the public policy underlying such laws, and (v) there is not in effect any order enjoining or restraining the Purchaser from entering into or engaging in any of the transactions contemplated by this Agreement.

  

9

  

5.09         Reliance on Representations and Warranties in this Agreement.  The Purchaser acknowledges that neither the Company nor any of the Company’s directors, officers, employees, affiliates, controlling persons, agents or representatives makes or has made any representation or warranty, either express or implied, as to the accuracy or completeness of any of the information or materials made available to the Purchaser or any of its directors, officers, employees, affiliates, controlling persons, agents or representatives, except as and only to the extent expressly set forth herein with respect to the representations and warranties made by the Company in Section 4 of this Agreement and subject to the limitations and restrictions thereon contained in this Agreement.

 

5.10         Transfer of Shares.  The Purchaser agrees that it will not effect any disposition of the Shares or its right to purchase the Shares other than in conformity with the requirements of the Securities Act and any applicable state or foreign securities laws.

 

SECTION 6.  Survival of Representations, Warranties and Agreements.  Notwithstanding any investigation made by either party to this Agreement, all covenants and agreements made by the Company and the Purchaser herein and in the certificates for the Purchaser Shares delivered pursuant hereto shall survive the execution of this Agreement, the delivery to the Purchaser of the Purchaser Shares and the payment therefor.  All representations and warranties made by the Company and the Purchaser herein and in the certificates for the Purchaser Shares delivered pursuant hereto shall survive for a period of one year following the later of the execution of this Agreement, the delivery to the Purchaser of the Purchaser Shares and the payment therefor.

 

SECTION 7.  Independent Nature of Purchasers’ Obligations and Rights.  The obligations of the Purchaser under this Agreement are several and not joint (or joint and several) with the obligations of any Other Purchaser, and the Purchaser shall not be responsible in any way for the performance of the obligations of any Other Purchaser under the Agreements.  The decision of the Purchaser to purchase the Purchaser Shares pursuant to this Agreement has been made by such Purchaser independently of any Other Purchaser.  Nothing contained in the Agreements, and no action taken by any Purchaser pursuant thereto, shall be deemed to constitute the Purchasers as a partnership, an association, a joint venture or any other kind of entity, or create a presumption that the Purchasers are in any way acting in concert or as a group with respect to such obligations or the transactions contemplated by the Agreements.  The Purchaser acknowledges that no Other Purchaser has acted as agent for such Purchaser in connection with making its investment hereunder and that no Other Purchaser will be acting as agent of such Purchaser in connection with monitoring its investment in the Purchaser Shares or enforcing its rights under this Agreement.  The Purchaser shall be entitled to independently protect and enforce its rights, including without limitation the rights arising out of this Agreement, and it shall not be necessary for any Other Purchaser to be joined as an additional party in any proceeding for such purpose.

 

SECTION 8.  Notices.  All notices required or permitted hereunder shall be in writing and shall be deemed effectively given: (i) upon delivery to the party to be notified; (ii) when received by confirmed facsimile.  All communications shall be sent to the Company and the Purchaser as follows or at such other addresses as the Company or the Purchaser may designate upon ten (10) days’ advance written notice to the other party:

  

10

  

(a)       if to the Company, to:

 

Digital Domain Institute, Inc

8881 South US Highway One

Port St. Lucie, FL 34952

Attn.: General Counsel

Facsimile: (772) 345-8113

(b)       if to the Purchaser, at its address as set forth on the signature pages to this Agreement.

 

SECTION 9.  Changes.  This Agreement may not be modified or amended except pursuant to an instrument in writing signed by the Company and the Purchaser.  Any amendment or modification effected in accordance with this Section 10 shall be binding upon each holder of any securities purchased under this Agreement at the time outstanding, each future holder of all such securities, and the Company.

 

SECTION 10. Headings.  The headings of the various sections of this Agreement have been inserted for convenience of reference only and shall not be deemed to be part of this Agreement.

 

SECTION 11. Severability.  In case any provision contained in this Agreement should be invalid, illegal or unenforceable in any respect, the validity, legality and enforceability of the remaining provisions contained herein shall not in any way be affected or impaired thereby.

 

SECTION 12. Governing Law; Venue.  This Agreement and any disputes or claims arising out of or in connection with its subject matter shall be governed by and construed in accordance with the laws of the State of New York without regard to the conflicts of laws principles of that or any other jurisdiction.  The parties irrevocably agree that the state and federal courts of the state of New York shall have exclusive jurisdiction to settle any dispute or claim that arises out of or in connection with this Agreement.  Each of the parties agrees to waive to the fullest extent permitted by applicable law any objection that it now has or may hereafter have to the venue of any litigation, proceeding or action arising out of, or in connection with, this Agreement being laid in any such court, or that any such litigation, proceeding or action was brought in an inconvenient forum.

 

SECTION 13. Counterparts.  This Agreement may be executed in one or more counterparts, each of which shall constitute an original, but all of which, when taken together, shall constitute but one instrument, and shall become effective when one or more counterparts have been signed by each party hereto and delivered (including by facsimile) to the other parties.

  

11

  

SECTION 14.  Entire Agreement. This Agreement (including the Appendices attached hereto) and the instruments referenced herein contain the entire understanding of the parties with respect to the matters covered herein and therein and, except as specifically set forth herein or therein, neither the Company nor the Purchaser makes any representation, warranty, covenant or undertaking with respect to such matters.

 

SECTION 15.  Fees and Expenses.  Except as expressly set forth herein, each of the Company and the Purchaser shall pay its respective fees and expenses related to the transactions contemplated by this Agreement.

 

SECTION 16.  Parties.  This Agreement is made solely for the benefit of and is binding upon the Purchaser and the Company and, except to the extent expressly provided in Section 17, no other person or entity shall acquire or have any right under or by virtue of this Agreement.

 

SECTION 17.  Assignment.  Except as otherwise expressly provided herein, the provisions hereof shall inure to the benefit of, and be binding upon, the parties hereto and their respective successors and assigns.  This Agreement and the rights of the Purchaser hereunder may be assigned by the Purchaser only with the prior written consent of the Company, except such consent shall not be required in cases of (i) assignments by an investment adviser to a fund for which it is the adviser or by or among funds that are under common control or (ii) any assignment by the Purchaser to an affiliate, provided that such transfer of securities shall not have been consummated in violation of the provisions of this Agreement and, provided further that, in each such case, such transferee agrees in writing to be bound by the terms of this Agreement.

 

SECTION 18.  Further Assurances.  Each party agrees to cooperate fully with the other party and to execute such further instruments, documents and agreements and to give such further written assurance as may be reasonably requested by the other party to evidence and reflect the transactions described herein and contemplated hereby and to carry into effect the intents and purposes of this Agreement.

 

[Remainder of Page Intentionally Left Blank;

 

Signatures Appear on the Following Two Pages]

  

12

  

IN WITNESS WHEREOF, the parties hereto have caused this Stock Purchase Agreement to be executed by their duly authorized representatives as of the day and year first above written.

 

	  	
DIGITAL DOMAIN INSTITUTE, INC.

	  	  
	  	
By:

	  
	  	
Name:

	  
	  	
Title:

	  

 

  

13

  

PURCHASER SIGNATURE PAGE

 

Print or Type:

 

	  	
Name of Purchaser

(Individual or Institution):

	  	  
	  	  
	  	  
	  	
Name of Individual representing

Purchaser (if an Institution):

	  	  
	  	  
	  	  
	  	
Title of Individual representing

Purchaser (if an Institution):

	  	  
	  	  

Signature by:

 

	  	
Individual Purchaser or Individual 

representing Purchaser:

	 	 
	 	 
	  	  
	  	
Address:

	  
	  	  	  
	  	
Telephone:

	  
	  	  	  
	  	
Facsimile:

	  

If the Shares are to be held by two or more joint holders, all such holders must sign.  When signing as attorney-in-fact, executor, administrator, trustee or guardian, please give full title as such.  If signing as a corporation, please sign in full corporate name by the President or other authorized officer.  If signing as a partnership or limited liability company, please sign in partnership or limited liability company name by an authorized person.

	

Number of Shares 

to Be Purchased

	 	

Price Per Share

In US Dollars

	 	

Aggregate 

Price In US Dollars

	  	 	$	 	 	  
	  	 	 	 	 	  
	  	 	 	 	 	  

 

  

14

  

 

SUMMARY INSTRUCTION SHEET FOR PURCHASER

 

(to be read in conjunction with the entire

Stock Purchase Agreement which this follows)

 

A.       Complete the following items on BOTH Stock Purchase Agreements (Please sign two originals):

 

	
  

	
1.

	
Signature Page:

 

	
  

	
(i)

	
Name of Purchaser (Individual or Institution)

 

	
  

	
(ii)

	
Name of Individual representing Purchaser (if an Institution)

 

	
  

	
(iii)

	
Title of Individual representing Purchaser (if an Institution)

 

	
  

	
(iv)

	
Signature of Individual Purchaser or Individual representing Purchaser

 

	
  

	
2.

	
Appendix I - Stock Certificate Questionnaire:

 

Provide the information requested by the Stock Certificate Questionnaire.

 

	
  

	
3.

	
Return BOTH properly completed and signed Stock Purchase Agreements including the properly completed Appendix II to (initially by facsimile with original copy by overnight delivery):

 

	  	
Digital Domain Institute, Inc.

	  	
8881 South US Highway One

	  	
Port St. Lucie, FL 34952

	  	
Attn.: Ed Lunsford

	  	
Facsimile: (772) 345-8113

B.           Instructions regarding the transfer of funds for the purchase of Shares will be sent by facsimile to the Purchaser at a later date.

  

15

  

Appendix I

 

STOCK CERTIFICATE QUESTIONNAIRE

 

Pursuant to Section 3 of the Agreement, please provide us with the following information:

 

	
1.

	
The exact name that your Shares are to be registered in (this is the name that will appear on your stock certificate(s)).  You may use a nominee name if appropriate:

 

	 	  
	  	  	 	  
	
2.

	
The relationship between the Purchaser of the Shares and the Registered Holder listed in response to item 1 above:

 

	 	  
	  	  	 	  
	
3.

	
The mailing address of the Registered Holder listed in response to item 1 above:

	 	  
	  	  	 	  
	  	  	 	  
	  	  	 	  

 

  

16

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00193-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00193-of-00352.parquet"}]]