Document:

exv10w24

 

Exhibit 10.24

JOINT DEVELOPMENT AGREEMENT

Regarding

COAL CONVERSION PROJECTS

By and Between

ASHMORE ENERGY INTERNATIONAL

And

SYNTHESIS ENERGY SYSTEMS, INC.

Dated this 10th day of July 2007

 

 

TABLE OF CONTENTS

	 	 	 	 	 
	ARTICLE 1 DEFINITIONS
	 	 	1	 
	ARTICLE 2 JOINT DEVELOPMENT
	 	 	7	 
	2.1 Project Development
	 	 	7	 
	2.2 Project Team
	 	 	7	 
	2.3 Participation Rights
	 	 	8	 
	2.4 Acceptance of a Project
	 	 	10	 
	2.5 Project Team Responsibilities
	 	 	11	 
	2.6 Rejection of a Project
	 	 	11	 
	2.7 No Power to Bind Project Company or the other Developer
	 	 	11	 
	2.8 Information
	 	 	12	 
	ARTICLE 3 RIGHTS AND OBLIGATIONS OF THE PARTIES
	 	 	12	 
	3.1 Joint Obligations
	 	 	12	 
	3.2 Rights and Obligations of AEI
	 	 	12	 
	3.3 Rights and Obligations of SES
	 	 	12	 
	3.4 Technology License
	 	 	14	 
	3.5 Equipment Sales and Support
	 	 	15	 
	ARTICLE 4 PROJECT COMPANIES
	 	 	15	 
	4.1 Formation of Project Companies
	 	 	15	 
	4.2 Wholly Owned Project Companies
	 	 	16	 
	4.3 Third Developer Interests in Project Companies
	 	 	16	 
	4.4 Supermajority Vote Requirements
	 	 	16	 
	4.5 Simple Majority Vote Requirements
	 	 	17	 
	4.6 Tie-Breaking Vote (Operating Budgets)
	 	 	17	 
	4.7 Appointment of Management
	 	 	17	 
	4.8 Policies and Procedures
	 	 	17	 
	4.9 Reimbursement of Development Costs
	 	 	17	 
	ARTICLE 5 WITHDRAWAL AND ASSIGNMENT
	 	 	17	 
	5.1 Withdrawal
	 	 	17	 
	5.2 Assignment
	 	 	18	 
	ARTICLE 6 CONFIDENTIALITY
	 	 	18	 
	6.1 Confidential Obligation
	 	 	18	 
	6.2 Use of Confidential Information
	 	 	19	 

 

 

TABLE OF CONTENTS (Cont’d)

	 	 	 	 	 
	6.3 Survival
	 	 	19	 
	ARTICLE 7 NOTICES
	 	 	19	 
	ARTICLE 8 REPRESENTATIONS AND WARRANTIES
	 	 	20	 
	8.1 Representations
	 	 	20	 
	8.2 Compliance with Law
	 	 	21	 
	8.3 Intellectual Property
	 	 	23	 
	ARTICLE 9 DEFAULT AND TERMINATION
	 	 	23	 
	9.1 Event of Default
	 	 	23	 
	9.2 Additional Events of Default
	 	 	23	 
	9.3 Violation of FCPA or OFAC
	 	 	24	 
	9.4 AEI Termination Right
	 	 	24	 
	9.5 SES Termination Rights
	 	 	24	 
	ARTICLE 10 APPLICABLE LAW AND DISPUTE RESOLUTION
	 	 	25	 
	10.1 Applicable Law
	 	 	25	 
	10.2 Dispute Resolution
	 	 	25	 
	10.3 No Immunity
	 	 	27	 
	ARTICLE 11 INDEMNIFICATION AND LIABILITY
	 	 	27	 
	11.1 Indemnification and Limitation on Liability
	 	 	27	 
	11.2 No Fiduciary Duty
	 	 	28	 
	11.3 Non-Recourse
	 	 	28	 
	ARTICLE 12 MISCELLANEOUS
	 	 	29	 
	12.1 Relationship of the Developers
	 	 	29	 
	12.2 Integration
	 	 	29	 
	12.3 No Oral Modifications
	 	 	29	 
	12.4 Effective Date; Term
	 	 	29	 
	12.5 Headings
	 	 	29	 
	12.6 Waiver
	 	 	29	 
	12.7 Counterparts
	 	 	30	 
	12.8 Public Announcements
	 	 	30	 
	12.9 Counterparts
	 	 	30	 

ii

 

TABLE OF CONTENTS (Cont’d)

LIST OF EXHIBITS

Exhibit “A” – Project Description

Exhibit “B” – Project Development Agreement

Exhibit “C” – Term and Conditions of Equipment Supply

LIST OF SCHEDULES

Schedule 1.19 – Emerging Market

Schedule 1.38 – Pre-Existing Projects

iii

 

JOINT DEVELOPMENT AGREEMENT

     This JOINT DEVELOPMENT AGREEMENT, is made and entered into this 10th day of July
2007, by and between ASHMORE ENERGY INTERNATIONAL, a corporation organized and existing under the
laws of Cayman Island (“AEI”), and SYNTHESIS ENERGY SYSTEMS, INC., a company organized and
existing under the laws of Delaware (“SES”). SES and AEI, together with any of their
respective Affiliates involved in the development of Prospective Projects or Projects as
contemplated herein, are sometimes hereinafter referred to individually as a “Developer”
and collectively as the “Developers”.

W I T N E S S E T H

     A. WHEREAS, SES owns an exclusive worldwide license to the U-GAS Technology (hereinafter
defined) and wishes to make AEI a customer of SES;

     B. WHEREAS, SES has filed a registration statement with the Securities and Exchange Commission
on Form SB-2 for an underwritten public offering;

     C. WHEREAS, AEI has provided SES an indication of interest with respect to acquiring 2,000,000
shares of common stock in such public offering;

     D. WHEREAS, AEI has extensive experience in developing and operating energy infrastructure
projects throughout the world and wishes to become a customer of SES; and

     E. WHEREAS, AEI and SES wish to undertake jointly the development of SynGas Projects in
Emerging Markets (each, as hereinafter defined).

     NOW, THEREFORE, in consideration of the mutual covenants herein contained and other good and
valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the
Developers agree as follows:

ARTICLE 1

DEFINITIONS

     The following terms, when used herein, shall have the meanings set forth below. The meanings
specified are applicable both to the singular and the plural and to the masculine and feminine
forms. In addition, throughout this Agreement, the word “includes” or “including” shall mean
“including without limitation”.

     1.1 “Acceptance Notice” has the meaning ascribed to such term in Section 2.3.8.

     1.2 “Accepted Engineering Practices” shall mean those requirements or practices which are
compatible with standards required by a registered architect, a registered professional
engineer, or other duly governing, regulating, licensing or recognized authority for the type
of work involved.

1

 

     1.3 “AEI” has the meaning ascribed to such term in the preamble.

     1.4 “Affiliate” means, with respect to any Person, any other Person directly or
indirectly (through one or more intermediaries) controlling, controlled by or under common
control with such Person, and for such purposes the term “control” shall mean the direct or
indirect ownership of more than fifty percent (50%) of the total outstanding voting powers or
equity securities of, or other ownership interests in, a Person.

     1.5 “Agreement” means this Joint Development Agreement, together with the exhibits and
other attachments hereto, which are incorporated by reference herein and made a part hereof,
as amended or modified from time to time.

     1.6 “Bankruptcy” has the meaning ascribed to such term in Section 9.2.1.

     1.7 “Claimant” has the meaning ascribed to such term in Section 10.2.3.

     1.8 “Coal” means anthracite, bituminous, sub-bituminous, lignite, cannel and waste from
coal cleaning/preparation facilities (including but not limited to middlings, coarse refuse,
gob, culm and gangue). Additionally, for the purposes of this Agreement, the term Coal would
additionally include oil shale, petroleum coke and other non-biomass solid and heavy liquid
hydrogen-carbon materials.

     1.9 “Coal and Biomass Mixture” means a feed stock for the gasifier that consists of no
less than sixty percent (60%) Coal and no more than forty percent (40%) organic material such
as wood, municipal waste, manures, agricultural residue and crops that can be converted to
energy.

     1.10 “Co-Developer” means, for each Project, the Developer that is not the Lead
Developer.

     1.11 “Confidential Information” has the meaning ascribed to such term in Section 6.1.

     1.12 “Developer” has the meaning ascribed to such term in the preamble.

     1.13 “Development Costs” means, with respect to any Project in which each Developer has a
Participating Interest, all actual, reasonable, direct and necessary costs and expenses
incurred by a Developer during the Term for the evaluation, research, study, development or
implementation of a given Project, including without limitation transportation, lodging,
courier, telecommunication and reproduction costs, consultant/advisor fees with prior approval
of the other Developer, and wages and salaries of personnel directly engaged in or
attributable to such work, at rates to be agreed by the Developers, which in no event will
exceed one hundred ten percent (110%) of actual costs.

     1.14 “Disposition” means any of (a) a sale, assignment, transfer, exchange, creation of a
trust or other disposition of any interest whether legal or beneficial in any asset or thing
(including in the case of any Participating Interest, any voting or other rights attached
thereto) and including, in any case, the acts comprised in or any agreement to do

2

 

any of the foregoing and a disposition by operation of law, or (b) a mortgage, pledge,
lien, charge (whether by way of fixed or floating charge), grant of security interest or other
encumbrance (whether equitable or legal) of any interest whether legal or beneficial in any
asset or thing, other than those that may be entered into by the Developers in connection with
limited recourse financing of a Project (including in the case of any equity interest, any
voting or other rights attached thereto) and including, in any case, the acts comprised in or
any agreement to do any of the foregoing.

     1.15 “Dispute” has the meaning ascribed to such term in Section 10.2.1.

     1.16 “Dollar” or “$” means the lawful currency of the United States of America.

     1.17 “Downstream Project” means each or any of a SynGas Chemical Project, a SynGas Power
Project or a SynGas Industrial Use Project.

     1.18 “Effective Date” means the date upon which this Agreement is approved by the board
of directors of both Developers as demonstrated by a notice to the other Developer of such
approval.

     1.19 “Emerging Markets” means those markets set forth on Schedule 1.19.

     1.20 “Equipment” shall mean all materials, supplies, equipment, spare parts and
facilities, of whatever nature, intended to become a permanent part of a Project, including
without limitation any of the foregoing that utilize all or any part of the U-GAS Technology.

     1.21 “Equipment Supply Agreement” means any agreement to provide, supply or sell
Equipment to any Project.

     1.22 “Exclusive Project” has the meaning ascribed to such term in Section 2.6.2.

     1.23 “External Engineering Support” shall mean engineering support services provided by
SES to a given Project using third-party personnel that has been contracted and compensated by
SES, which services shall include, without limitation, design, engineering and process
requirements; design and process methodology (including underlying engineering methods),
design and process philosophy, component features; engineering experience, engineering
analysis, processing, operations and construction know-how, including the processing,
operations and construction techniques and processes needed for coal regasification.

     1.24 “FCPA” means the United States Foreign Corrupt Practices Act of 1977 (15 U.S.C. §§
78dd-1, et seq.), as amended.

     1.25 “Final Investment Decision” means, with respect to any Project, the decision by the
board of directors of any Project Company to proceed with such Project as demonstrated by the
approval to (a) fund the equity required to develop such Project, (b) issue full notice to
proceed under the construction contracts, (c) execute any Project Contracts not yet executed,
and perform under all Project Contracts, or (d) execute, deliver

3

 

and perform any Financing Agreements and material related documents required for the
development of such Project.

     1.26 “Financing Agreement” means each or any of:

          (a) the Project Company’s agreements with other Persons for the provision to the Project
Company of loans, credit facilities, or other funds (other than by way of equity
participation) for the design, construction, and procurement of Equipment for the Projects and
any term financing to replace any such prior financings; and

          (b) the security documents, direct agreements, and other ancillary undertakings in favor
of the Lenders or their designees required pursuant to the agreements referred to in clause
(a) above.

     1.27 “Government Official” means any employee or officer of a government including any
national, regional or local department, agency, or enterprise owned or controlled by a
government, any official of a political party, any official or employee of a public
international organization, any person acting in an official capacity for, or on behalf of,
such entities, and any candidate for foreign political office.

     1.28 “Governmental Authority” means any government, political subdivision, court or any
agency, instrumentality, or authority of the foregoing.

     1.29 “GTI” means the Gas Technology Institute, a research, development and training
organization serving the natural gas industry and energy markets.

     1.30 “Holding Company” has the meaning ascribed to such term in Section 4.3.

     1.31 “ICC” has the meaning ascribed to such term in Section 10.2.2.

     1.32 “Indemnitees” has the meaning ascribed to such term in Section 11.1.2.

     1.33 “Internal Engineering Support” shall mean engineering support services provided by
SES to a given Project using SES employees and internal personnel, which services shall
include, without limitation, design, engineering and process requirements; design and process
methodology (including underlying engineering methods), design and process philosophy,
component features; engineering experience, engineering analysis, processing, operations and
construction know-how, including the processing, operations and construction techniques and
processes needed for coal regasification.

     1.34 “Lead Developer” has the meaning ascribed to such term in Section 2.4.2.

     1.35 “Lenders” mean the Persons providing loans or credit under the Financing Agreements
or a trustee or agent acting for them.

     1.36 “OFAC” has the meaning ascribed to such term in Section 8.1.6.

4

 

     1.37 “Participating Interest” has the meaning ascribed to such term in Section 2.3.2.

     1.38 “Person” means any individual, partnership, corporation, limited liability company,
unlimited liability company, association, joint stock company, trust, joint venture,
unincorporated organization, governmental entity (or any department, agency or political
subdivision thereof) or any other entity.

     1.39 “Pre-Existing Project” means those projects set forth on Schedule 1.38 that
were in existence prior to the Effective Date, including any expansion thereof.

     1.40 “Project” means each or any of a SynGas Project or a Downstream Project.

     1.41 “Project Company” has the meaning ascribed to such term in Section 4.1.1.

     1.42 “Project Contracts” means all those agreements relating to the development, design,
construction, testing, commissioning, operation, and maintenance of a Project, including land
acquisition, right of way agreements, engineering, procurement, and construction contracts,
coordination agreements with respect to construction and testing of the Project, operating and
maintenance agreements, land deeds, easements, rights-of-way, government implementation or
support agreements, all third-party financing agreements, government approvals, licenses and
permits, but excluding agreements relating to the ownership and corporate governance of any
Project Company.

     1.43 “Project Development Agreement” has the meaning ascribed to such term in Section
2.4.1.

     1.44 “Project Support” has the meaning ascribed to such term in Section 3.3.2.

     1.45 “Project Team” has the meaning ascribed to such term in Section 2.2.1.

     1.46 “Project Team Representative” has the meaning ascribed to such term in Section
2.2.2.

     1.47 “Prospective Project” means each or any of a Prospective SynGas Project, a SynGas
Chemical Project, a SynGas Power Project or SynGas Industrial Use Project located in an
Emerging Market.

     1.48 “Prospective SynGas Project” means any Syngas Project identified by a Developer that
involves converting Coal or Coal and Biomass Mixture into SynGas.

     1.49 “Representative” has the meaning ascribed to such term in Section 10.2.1.

     1.50 “Respondent” has the meaning ascribed to such term in Section 10.2.3.

     1.51 “Rules” has the meaning ascribed to such term in Section 10.2.2.

     1.52 “SES” has the meaning ascribed to such term in the preamble.

5

 

     1.53 “SynGas” means a gaseous mixture at ambient temperature and pressure that contains
varying amounts of carbon monoxide and hydrogen generated by the gasification of a carbon
containing fuel to a gaseous product with a heating value.

     1.54 “SynGas Chemical Project” means a SynGas Project to produce SynGas, together with a
related downstream project that utilizes SynGas or methane as a feed stock and chemically
alters such SynGas or methane in order to produce a refined product, including without
limitation, methanol, ethanol and ammonia.

     1.55 “SynGas Industrial Use Project” means a SynGas Project that provides SynGas to an
industrial project as fuel in order to generate thermal energy, or to a gas distribution
system in order to distribute such SynGas to a third party that will in turn consume such
SynGas in order to generate thermal energy, including, without limitation, town gas
distribution systems, boilers and process heating.

     1.56 “SynGas Power Project” means a SynGas Project that provides SynGas to an associated
thermoelectric power plant which in turn utilizes such SynGas as the principle fuel source in
order to generate electricity.

     1.57 “SynGas Project” means the development, design, construction, financing, operation,
and maintenance by AEI, SES or any Holding Company or Project Company, pursuant to the terms
of this Agreement, of a coal conversion facility that involves the gasification of coal by
U-GAS Technology or an alternative technology for use in power, chemicals, transportation
fuels or other energy uses.

     1.58 “Technical Support” shall mean technical support for the operation and maintenance
of Equipment, components, facilities, systems, subsystems, auxiliaries and accessories
utilizing all or any part of the U-GAS Technology.

     1.59 “Term” has the meaning ascribed to such term in Section 12.4.

     1.60 “Termination Date” has the meaning ascribed to such term in Section 5.1.

     1.61 “Training” shall mean orientation, education and instruction in the use,
implementation and operation of the Equipment and the U-GAS Technology intended to become a
permanent part of a Project, including without limitation the following:

                    (a) instruction and education, in amounts and at times to be agreed by the Developers,
regarding the start-up, operation, shutdown and maintenance of Equipment, components,
facilities, systems, subsystems, auxiliaries and accessories utilizing all or any part of the
U-GAS Technology;

                    (b) manuals, diagrams, drawings, checklists, and other written information regarding the
start-up, operation, shutdown and maintenance of Equipment, components, facilities, systems,
subsystems, auxiliaries and accessories utilizing all or any part of the U-GAS Technology;

6

 

                    (c) written identification of necessary and desirable short and long term spare part
inventories, maintenance supplies, special tools and Equipment for a Project;

                    (d) emergency procedures for a Project, including with regards to Equipment, components,
facilities, systems, subsystems, auxiliaries and accessories utilizing all or any part of the
U-GAS Technology; and

                    (e) safety procedures and precautions for a Project, including with regards to Equipment,
components, facilities, systems, subsystems, auxiliaries and accessories utilizing all or any
part of the U-GAS Technology.

     1.62 “Tribunal” has the meaning ascribed to such term in Section 10.2.3.

     1.63 “U-GAS Technology” means a process involving conversion of coal to fuel gas by
reaction of coal with air at over 75 psia with the addition of steam, carbon dioxide or other
diluent gases in a fluidized bed reactor system with a sloping grid and central nozzle in
which high carbon conversion is obtained by utilizing techniques with or without ash
agglomeration with control of ash sintering and the withdrawal of high ash material or
agglomerates, wherein crushed coal is fed directly into the fluidized bed with recycle of coal
dust or char fines entrained in effluent gas back into the fluidized bed.

ARTICLE 2

JOINT DEVELOPMENT

     2.1 Project Development.

               2.1.1 On and subject to the terms set forth in this Agreement, each of the Developers will
seek to identify Prospective Projects. In connection therewith, AEI shall be a customer of SES.

               2.1.2 Any Pre-Existing Project announced by either Developer prior to the Effective Date does
not constitute a Project for the purposes of this Agreement and no Developer shall have any
obligation to present any Pre-Existing Project to the Project Team or to offer the other Developer
a right to participate in such Pre-Existing Project.

     2.2 Project Team.

               2.2.1 For the purposes of evaluating Prospective Projects, the Developers shall establish a
committee (the “Project Team”) pursuant to this Section 2.2.

               2.2.2 The Project Team shall be comprised of two (2) representatives of each Developer (each,
a “Project Team Representative”). Within thirty (30) days of the execution of this
Agreement, each Developer shall designate by written notice to the other Developer the names of its
Project Team Representatives. From time to time, each Developer shall be entitled to remove or
substitute any Project Team Representative appointed by it, or to designate a replacement Project
Team Representative, by providing written notice of such removal and

7

 

appointment to the other Developers. The Project Team shall meet at such times and at such
places as may be determined by the Project Team Representatives. Each Developer shall have the
right to bring those advisors, consultants or representatives as it deems necessary to any Project
Team meeting. The Project Team shall establish such rules and procedures as it deems necessary and
prudent in order to give effect to the purposes hereof.

          2.2.3 The Project Team Representatives shall consult with each other from time to time in
order to ensure effective communication between the Developers regarding development of all aspects
of any Prospective Project or Project. In this regard, the Project Team Representative of each
Developer shall be specifically authorized by that Developer to give and to receive any Acceptance
Notice. All other notifications shall be governed by Article 7.

     2.3 Participation Rights.

          2.3.1 In the event any Developer identifies a Prospective Project, such Developer shall
present the Prospective Project, together with the information set forth on Exhibit “A”
(including without limitation the proposed Lead Developer for the Project), for the evaluation and
review of the Project Team. Project Team Representatives shall have the right to request
additional information or clarifications regarding the Prospective Project and to review such
information as may be available in order to evaluate such Prospective Project.

          2.3.2 Upon presentation of a Prospective Project to the Project Team, the non-presenting
Developer shall have the right, but not the obligation, to participate in the benefits, rights,
liabilities and other obligations, including the acquisition of equity capital, held by the
presenting Developer in such Prospective Project (a “Participating Interest”) in an amount
determined in accordance with this Section 2.3. The Developers acknowledge and agree that such
Participating Interest may represent less than fifty percent (50%) of the total outstanding
interests in such Prospective Project as the result of the participation of a third party in such
Prospective Project.

          2.3.3 Upon presentation of a SynGas Project utilizing U-GAS Technology to the Project Team,
the non-presenting Developer shall have the right, but not the obligation, to participate in an
amount up to fifty percent (50%) of Participating Interest held by the presenting Developer in such
SynGas Project.

          2.3.4 Upon presentation of a SynGas Chemical Project to the Project Team, the following
provisions shall apply:

               (a) If the SynGas Chemical Project has SynGas as a feedstock that is derived from a Project
that utilizes U-GAS Technology, the non-presenting Developer shall have the right, but not the
obligation, to participate in an amount up to fifty percent (50%) of the Participating Interest
held by the presenting Developer in such SynGas Chemical Project (including both the SynGas Project
and associated chemicals project).

               (b) If the SynGas Chemical Project has SynGas as a feedstock that is derived from a Project
that does not utilize U-GAS Technology, the non-presenting Developer shall have the right,
but not the obligation, to participate in an amount up to thirty-five percent

8

 

(35%) of the Participating Interest held by the presenting Developer in such SynGas Chemical
Project (including both the SynGas Project and associated chemicals project).

          2.3.5 Upon presentation of a SynGas Power Project to the Project Team, the following
provisions shall apply:

               (a) If the SynGas Power Project has SynGas as a feedstock that is derived from a Project that
utilizes U-GAS Technology, the non-presenting Developer shall have the right, but not the
obligation, to participate in an amount up to fifty percent (50%) of the Participating Interest
held by the presenting Developer in the SynGas Project (but not the associated power plant).

               (b) If the SynGas Power Project has SynGas as a feedstock that is derived from a Project that
does not utilize U-GAS Technology, the non-presenting Developer shall have no right to
participate in such SynGas Project in any capacity whatsoever.

          2.3.6 Upon presentation of an SynGas Industrial Use Project to the Project Team, the following
provisions shall apply:

               (a) If the SynGas Industrial Use Project has SynGas as a feedstock that is derived from a
Project that utilizes U-GAS Technology, the non-presenting Developer shall have the right, but not
the obligation, to participate in an amount up to fifty percent (50%) of the Participating Interest
held by the presenting Developer in the SynGas Project (but not the associated industrial use or
gas distribution project).

               (b) If the SynGas Industrial Use Project has SynGas as a feedstock that is derived from a
Project that does not utilize U-GAS Technology, the non-presenting Developer shall have the
right, but not the obligation, to participate in an amount up to twenty-five percent (25%) of the
Participating Interest held by the presenting Developer in the SynGas Project (but not the
associated industrial use or gas distribution project).

          2.3.7 Notwithstanding any provision herein to the contrary, the parties acknowledge and agree
that with respect to any upstream project, each Developer shall use commercially reasonable efforts
to give to the non-developing party the right to participate in such upstream project; provided,
however, that no Developer or any of its Affiliates shall have any liability under this Agreement
if such Developer is unable to offer a Participating Interest in any such upstream project after
using its commercially reasonable efforts as required by this Section 2.3.7.

          2.3.8 Within thirty (30) days of the presentation of a Prospective Project to the Project
Team, any Developer that wishes to participate in such Prospective Project shall forward a notice
executed by a Project Team Representative accepting a Participating Interest in such Prospective
Project (an “Acceptance Notice”). This issuance of an Acceptance Notice shall indicate
such Developer’s interest in entering into a Project Development Agreement with respect to such
Project, but in no event shall such Acceptance Notice be deemed the making of a Final Investment
Decision regarding such Project.

9

 

          2.3.9 The failure of any Developer to respond within such thirty (30) day notice period shall
be deemed a rejection of such Prospective Project.

          2.3.10 Following the presentation to the Project Team and election by each Developer to
participate in a Prospective Project, such Prospective Project shall be referred to herein as a
“Project” for all purposes hereof.

     2.4 Acceptance of a Project.

          2.4.1 If, pursuant to an Acceptance Notice, each Developer elects to participate in a given
Project, the Developers shall agree to the overall development and implementation of the Project as
soon a reasonably practicable by executing a project development agreement, substantially in the
form attached hereto as Exhibit “B” (each such agreement, a “Project Development
Agreement”).

          2.4.2 The appointment of one of the Developers as the lead developer (the “Lead
Developer”) for such Project shall be included in each Project Development Agreement. The Lead
Developer for each Project shall be determined on a case-by-case basis. The Lead Developer shall
oversee the overall development of such Project. Subject to the voting requirements set forth in
the Project Development Agreement, the Lead Developer shall have the right to make decisions
regarding, and shall perform (or shall contract with others to perform) all activities relating to
the development of the Project. The Lead Developer shall keep the Co-Developer informed of
development plans and the status of development and shall consider in good faith any suggestions by
the Co-Developer regarding the Project’s development.

          2.4.3 In connection with the development of any Project, the Developers anticipate that the
Lead Developer will undertake the following types of activities in order develop the Project:

               (a) Acquiring a project site suitable for the development of the Project;

               (b) Obtaining all governmental authorizations required for the development of the Project;

               (c) Leading negotiations on a turn-key engineering, procurement and construction contract for
the design, engineering, procurement, construction, start-up, testing and commissioning of the
Project;

               (d) Leading negotiations on fuel supply arrangements and off-take arrangements;

               (e) Obtaining any required financing for the Project;

               (f) Acquiring any real property interests to the extent necessary to develop the Project;

               (g) Leading negotiations on technical support agreements and technology licenses; and

10

 

               (h) Taking any and all other actions necessary and convenient for the development,
construction, financing, operation and maintenance of the Project in accordance with the terms of
this Agreement and the applicable Project Development Agreement.

     2.5 Project Team Responsibilities.

          2.5.1 In addition to any items set forth in the Project Development Agreement, the Project
Team and the Project Team Representatives shall perform the following functions:

               (a) Following appointment of a Lead Developer in accordance with Exhibit “B”, the
Project Team Representatives of the Co-Developer and Lead Developer shall coordinate the day-to-day
performance of their respective representatives as agreed by the parties.

               (b) Each Developer’s Project Team Representatives will be informed and consulted by the other
Developer regarding decisions, development plans and the status of development of any Project.
Such Developer’s representatives will, where practicable, be invited to all negotiations and
meetings regarding any Project Contracts and the Financing Agreements and to meetings regarding
other matters relating to any Project. Any Project Contract with a Developer’s Affiliate will be
arm’s length and competitive with those that have been or would be offered to or by third parties.

               (c) In connection with those actions that require the unanimous consent of all the Developers
pursuant to the terms hereof or any Project Development Agreement, the Project Team Representative
of each Developer shall be authorized to participate and vote at any meeting held and to evidence
the consent of such Developer.

               (d) Subject to the other provisions of this Agreement, the Project Team Representatives shall
in good faith attempt to resolve any disputes that may arise among the Developers under this
Agreement or in connection with the development of any Project.

          2.5.2 The Project Team and the Project Team Representatives shall perform all other actions
specifically described in this Agreement as being performed by the Project Team and the Project
Team Representatives.

     2.6 Rejection of a Project.

          2.6.1 If a Developer declines to participate in a given Project or the period of time for
providing an Acceptance Notice expires, such Developer shall have no further right to acquire a
Participating Interest in such Project.

          2.6.2 Any Developer electing to proceed with a Project without the participation of the other
Developer (an “Exclusive Project”) shall bear the entire cost and liability of such
Exclusive Project.

     2.7 No Power to Bind Project Company or the other Developer. Neither Developer nor
any Affiliate of either Developer may take any action purporting to bind a Project Company, the
other Developer, or its Affiliates, except as provided in this Agreement, any

11

 

Project Development Agreement or in the Project Contracts. All actions undertaken by the
Developers and their Affiliates, or any of them, are at their sole risk and expense except to the
extent, if any, that the Project Company assumes those obligations by executing Project Contracts
or other documents in accordance with this Agreement or any Project Development Agreement. This
Agreement is not intended to create, and shall not be construed as creating, a partnership or joint
venture. Neither Developer is an agent, employee, contractor, vendor, representative or partner of
the other Developer, and a Developer may not hold itself out as such; provided, however, that
Developers and their Affiliates may be parties to Project Contracts, any Project Development
Agreement or holders of interests in any Project Company.

     2.8 Information. Each Developer shall furnish to the other Developer such information
concerning the development of each Project in such detail and with such frequency as the other
Developer reasonably may require, including but not limited to information required for a Developer
or its Affiliates to prepare their tax returns on a timely basis.

ARTICLE 3

RIGHTS AND OBLIGATIONS OF THE PARTIES

     3.1 Joint Obligations. In performing its obligations under this Agreement, each
Developer shall cooperate fully with the other Developer to that end. The Developers shall use all
reasonable efforts to negotiate and execute any and all agreements in connection therewith and on
terms and conditions consistent with this Agreement and otherwise mutually acceptable to the
Developers.

     3.2 Rights and Obligations of AEI.

          3.2.1 Project Identification. AEI shall use its commercially reasonably efforts to
identify and secure Prospective Projects. All decisions related to the methodology for identifying
Prospective Projects and the resources dedicated to fulfill the requirements of AEI under this
Agreement with respect to the identification and development of Prospective Project shall be made
at the sole discretion of AEI. AEI shall notify SES of each Prospective Project identified by AEI
pursuant to Section 2.3.1.

     3.3 Rights and Obligations of SES.

          3.3.1 Project Identification. SES shall use its commercially reasonably efforts to
identify and secure Prospective Projects. All decisions related to the methodology for identifying
Prospective Projects and the resources dedicated to fulfill the requirements of SES under this
Agreement with respect to the identification and development of Prospective Project shall be made
at the sole discretion of SES. SES shall notify AEI of each Prospective Project identified by SES
pursuant to Section 2.3.1.

          3.3.2 Project Support. To the extent reasonably requested by AEI for any Prospective
Project, or contemplated under the applicable Project Development Agreement for any Project, SES
shall provide or cause to be provided the equipment, materials and support services to such
Prospective Project or Project that are typical of the level and type of support

12

 

provided in similar projects by an owner’s engineer, notwithstanding any decision by SES not
to participate in such Project (collectively, “Project Support”):

               (a) Internal Engineering Support, in compliance with Accepted Engineering Practices and all
applicable national, state and local engineering, construction, operating, processing, safety and
codes and standards in effect on the effective date of this Agreement;

               (b) External Engineering Support, in compliance with Accepted Engineering Practices and all
applicable national, state and local engineering, construction, operating, processing, safety and
codes and standards in effect on the effective date of this Agreement;

               (c) Equipment sales, support and services to the Project, pursuant to an Equipment Supply
Agreement, which if entered into between the Project Company and SES, will have the general terms
and conditions of which are set forth in Exhibit “C”;

               (d) Training; and

               (e) Technical Support.

          3.3.3 Reimbursement.

               (a) With respect to any Prospective Project, to the extent Project Support is requested by AEI
in writing, SES shall be reimbursed by AEI within thirty (30) days of receipt of an invoice for
such Project Support as follows:

                         (i) For any Internal Engineering Support, External Engineering Support, Training or Technical
Support, SES shall be reimbursed at one hundred and ten percent (110%) of the actual, reasonable,
direct and necessary costs and expenses incurred by SES in providing such support services to such
Prospective Project, including without limitation transportation, lodging, courier,
telecommunication and reproduction costs, consultant fees (with prior approval of AEI), and wages
and salaries of personnel directly engaged in or attributable to such work, at rates to be agreed
by SES; and

                         (ii) Any Equipment sales will be reimbursed in accordance with the Equipment Supply Agreement.

               (b) With respect to any Project in which SES does not have a Participating Interest,
to the extent Project Support is requested by AEI in writing, SES shall be reimbursed by AEI within
thirty (30) days of receipt of an invoice for such Project Support as follows:

                         (i) For any Internal Engineering Support, External Engineering Support, Training or Technical
Support, SES shall be reimbursed at one hundred and ten percent (110%) of the actual, reasonable,
direct and necessary costs and expenses incurred by SES in providing such support services to such
Project, including without limitation transportation, lodging, courier, telecommunication and
reproduction costs, consultant fees (with

13

 

prior approval of the AEI), and wages and salaries of personnel directly engaged in or
attributable to such work, at rates to be agreed by SES; and

                         (ii) Any Equipment sales will be reimbursed in accordance with the Equipment Supply Agreement.

               (c) With respect to any Project in which SES has a Participating Interest, SES shall be
reimbursed in accordance with the applicable Project Development Agreement.

     3.4 Technology License. In addition to the Project Support obligations set forth in
Section 3.3.2, SES, as the licensor of the U-GAS Technology, shall grant and confirm to AEI or any
Project Company, as applicable, an exclusive, non-transferable license and right to use the U-GAS
Technology for coal conversion in connection with each Project. SES shall be required to grant a
license to use the U-GAS Technology in connection with a Project pursuant to this Section 3.4
regardless of whether SES chooses to acquire a Participating Interest in such Project. In
consideration of the license granted herein, SES shall be compensated as follows:

          (a) AEI agrees to pay to SES for each U-GAS unit licensed, designed, built and/or operated by
or for AEI or the Project Company an upfront royalty of $10 for each Thermal MegaWatt/hr
(MWt) of dry SynGas production of rated design capacity of the U-GAS system. The
royalty shall be paid in two equal installments: the first installment shall be paid upon the
execution of the license and/or contract for the construction of the U-GAS system; and the last
installment shall be paid upon the completion of the build of the U-GAS system. If the U-GAS
system consists of more than one unit to be built over a period of years, then the second
installment of the royalty shall be paid proportionately at the completion of each unit.

          (b) If both SES and AEI participate in a given Project, an energy royalty fee shall be in the
form of a profit sharing arrangement to be negotiated by the Developers on a case-by-case basis for
each Project at the time of the Final Investment Decision, subject to the condition that SES hereby
agrees it will offer AEI an energy royalty fee on terms not less favorable than those accepted by
SES in other projects in which SES has no equity participation; provided, however; that in no event
shall the royalty fee paid pursuant to this Section 3.4(b) exceed $0.50 per MMBtu of SynGas.

          (c) If AEI is the sole Developer with a Participating Interest in a given Project, the energy
royalty fee will be negotiated between SES and AEI, subject to the condition that SES hereby agrees
it will offer AEI an energy royalty fee on terms not less favorable than those accepted by SES in
other projects in which SES has no equity participation; provided, however; that in no event shall
the royalty fee paid pursuant to this Section 3.4(c) exceed $0.50 per MMBtu. The royalty fee,
which may take the form of profit sharing, a carried interest or royalty structure which changes as
financial hurdles are satisfied, will take into account, inter alia, the size of the project, the
application of the U-GAS Technology, the relative profitability of the project and any other
license agreements that have been entered into by SES; provided, however, that SES is obligated to
provide license at a fee of $0.50 per MMBtu of SynGas.

14

 

     Notwithstanding the SES obligations set forth in Section 3.3, SES shall have no obligation to
provide any technical support or a license to use the U-GAS Technology for any coal conversion
projects which do not utilize U-GAS Technology.

     3.5 Equipment Sales and Support.

          3.5.1 In connection to the obligation to provide U-GAS Technology to Projects independent of
whether SES may have any Participating Interest in such Project, SES hereby undertakes to provide
Equipment, support and services to each such Project, pursuant to an Equipment Supply Agreement,
the general terms and conditions of which are set forth in Exhibit “C”. The parties
acknowledge and agree that SES shall have the right to engage in direct Equipment sales and
licensing to third parties in Emerging Markets, provided that each such third party shall use such
Equipment to produce SynGas predominantly for its own internal consumption.

ARTICLE 4

PROJECT COMPANIES

     4.1 Formation of Project Companies.

          4.1.1 The Developers intend that each Project will be constructed, financed, owned, and
operated through one or more special-purpose company, partnership, or other entity or association
(each, a “Project Company”).

          4.1.2 The Project Company will have the following features, along with such other features as
the Developers may agree:

          (a) Subject to any third party rights, the initial equity owners will be Affiliates of the
Developers, and will be obligated to make contributions and be entitled to receive distributions on
a pro rata basis based upon their respective Participating Interests.

          (b) The Project Company will be formed under the laws of the jurisdiction determined by the
Lead Developer, taking into account the tax impacts or benefits to each Developer of such choice.

          (c) The Project Company’s sole purpose shall be conducting activities relating to the Project.

          (d) Unless otherwise agreed, any Developer may transfer its Participating Interest in any
Project Company only (i) to an Affiliate of the Developer or (ii) with the prior consent of a
majority-in-interest of the other unrelated equity owners. If required under the Financing
Agreements and any Developer is not otherwise precluded from doing so due to some other contractual
or legal obligation, each Developer will pledge its interests in the Project Company to the lenders
or their representatives.

15

 

          (e) The Developers will use reasonable efforts to ensure that the management structure of each
Project Company permits AEI to consolidate all Project Companies for accounting purposes, pursuant
to generally accepted accounting rules in the United States.

     4.2 Wholly Owned Project Companies. If a Project Company is owned in its entirety by
AEI and SES (i.e., no third party owns any interest in such Project Company), then AEI and SES
shall have representation on the board of directors of such Project Company in proportion to the
Participating Interest held by each of AEI and SES. For the avoidance of doubt, if each of AEI and
SES owns a fifty percent (50%) interest in a Project Company, then each shall have equal
representation on the board of directors of such Project Company.

     4.3 Third Developer Interests in Project Companies. If any third party or parties
owns any interest in a Project Company, then AEI and SES shall form a holding company (a
“Holding Company”) which will own the combined interest of AEI and SES in the Project
Company. AEI and SES shall have representation on the board of directors of such Holding Company
in proportion to the ownership interest held by each of AEI and SES in such Holding Company. For
the avoidance of doubt, if each of AEI and SES owns a fifty percent (50%) interest in a Holding
Company, then each shall have equal representation on the board of directors of such Holding
Company. The board of directors of the Holding Company shall appoint board members of the Project
Company owned by such Holding Company. Subject to any fiduciary obligations, the board members
will vote under the direction of the Holding Company according to the Holding Company’s
shareholders’ agreement.

     4.4 Supermajority Vote Requirements. The following items will require supermajority
votes of at least seventy percent (70%) of the board of directors for Holding Companies or Project
Companies controlled by AEI and SES:

               (a) material dispositions or acquisitions;

               (b) entering into or amending, modifying, waiving any right or initiating any dispute
resolution provision under any Project Contracts;

               (c) the approval of all construction budgets for any Project or material change orders;

               (d) the issuances of new equity or other material changes to capital structure;

               (e) the amendment of the organizational documents;

               (f) the incurrence by the Project Company of debt in excess of fifty percent (50%) of the
assets of such Project Company; and

               (g) any transaction between (i) a Project Company or Holding Company and (ii) any Developer or
an Affiliate of any Developer.

16

 

     4.5 Simple Majority Vote Requirements. All items to be voted upon by the board of
directors of any Holding Company or Project Company that are not listed in Section 4.4 shall
require a simple majority vote.

     4.6 Tie-Breaking Vote (Operating Budgets). With respect to any matter involving the
operating budget of a Project, to be determined by a simple majority vote, AEI’s vote shall be used
to break any tie in the voting of the board of directors.

     4.7 Appointment of Management. For all Project Companies, AEI shall have the right to
appoint the General Manager (Chief Executive Officer) and either a Controller or a Chief Financial
Officer. SES shall have the right to appoint the Deputy General Manager (Chief Operating Officer)
and the Operations Manager for the Syngas Project for all Project Companies.

     4.8 Policies and Procedures. AEI shall have the right to implement its corporate
policies and procedures in any Project Company controlled by AEI and SES. Such policies and
procedures shall include, without limitation: (a) policies related to the FCPA; (b) Code of
Conduct; and (c) Finance, Treasury and Accounting, which shall comply with the minimum requirement
of SES imposed upon it as a public company. AEI shall consider SES’ policies and procedures and
implement the same to the extent that they do not conflict in a negative way with AEI’s required
policies and procedures.

     4.9 Reimbursement of Development Costs. With respect to any Project in which each
Developer has a Participating Interest, each Developer and its Affiliates shall be reimbursed for
any Development Costs incurred in the development of such Project in accordance with the terms and
conditions of the applicable Project Development Agreement.

ARTICLE 5

WITHDRAWAL AND ASSIGNMENT

     5.1 Withdrawal.

          5.1.1 A Developer may withdraw from development of any Project at any time prior to the Final
Investment Decision upon written notice to the other Developer, subject to executing any documents
and obtaining any consent required to effect the assignments contemplated by this Section 5.1.1. A
Developer’s withdrawal from the Project shall become effective on the date such written notice is
delivered to the other Developer (the “Termination Date”). A withdrawing Developer shall
have no further obligations to the other Developer with respect to the Project, except for (a) its
share of costs incurred, accrued, or otherwise contractually committed to the Project as of the
Termination Date, (b) the survival of its confidentiality obligations pursuant to Section 6.3, and
(c) any other obligations set forth in this Section 5.1. Effective on the Termination Date, a
withdrawing Developer shall (i) have no residual interest or claim to the Project; and (ii) release
and transfer its Participating Interests in the Project Company.

          5.1.2 Any Developer that fails to make any mandatory funding obligations or otherwise fails to
comply with any capital contribution obligation under any Project Development Agreement shall be
deemed to have withdrawn from such Project as of the date of

17

 

such failure to make such funding obligation or capital contribution and the procedures set
forth in Section 5.1.1 shall apply.

     5.2 Assignment.

          5.2.1 Unless otherwise agreed in a Project Development Agreement or shareholder agreement, no
Developer shall directly or indirectly enter into any transaction for the Disposition of any of its
Participating Interest or its interest in this Agreement without the prior written consent of the
other Developer, which consent may be withheld for any reason; provided, however, that any parent
entity of a Developer may mortgage, pledge, place a lien or charge (whether by way of fixed or
floating charge), grant a security interest, or otherwise encumber (whether equitable or legal) as
security for borrowed money any interest whether legal or beneficial in a Developer, or in any
entity between such parent entity and a Developer in the respective Developer’s chain of ownership
by giving notification thereof to the other Developer.

          5.2.2 The Developers acknowledge and agree that breach of this Section 5.2 may not be
compensable by payment of money damages and, therefore, if any dispute arises concerning the
Disposition of all or any portion of any Participating Interest or its interest under this
Agreement, the Developers agree not to object to an injunction being issued on the application of
any Developer restraining such Disposition or rescinding or suspending any such Disposition pending
resolution of the dispute. Such remedies shall be cumulative and non-exclusive and shall be in
addition to any other rights and remedies the Developers may have under this Agreement or at law.

ARTICLE 6

CONFIDENTIALITY

     6.1 Confidential Obligation. Except as hereinafter provided, the provisions of this
Agreement and all information or documents which come into the possession of the Developers in
connection with the performance of this Agreement, including any and all data, information, plans,
proposals, contracts, or other materials related to the design, construction, configuration,
financing, or operation of any Project (including the U-Gas Technology under the license with GTI)
which are delivered or disclosed by a Developer to the other Developer under this Agreement, or
developed and paid for jointly by the Developers (the “Confidential Information”), may not
be used or communicated to third parties without mutual written agreement of the other Developer.
However, any Developer shall have the right to disclose such provisions, information or document
without the other Developer’s consent:

          (a) to legal counsel, accountants, auditors, financial advisers, lenders, other professional
consultants, shareholders, rating agencies, financial underwriters and insurance underwriters for a
Developer or any of its Affiliates, provided such disclosure is solely to assist such Person in
performing the functions for which they were engaged in connection with any Project, and for
recipients other than legal counsel, the recipient undertakes to keep such information or documents
under terms of confidentiality equivalent to this ARTICLE 6;

18

 

                    (b) if required by any court of law or any law, rule, or regulation having jurisdiction over a
Developer, or if requested or required by an agency of any government having or asserting
jurisdiction over a Developer, any guarantor of such Developer’s obligations hereunder, or any of
their respective Affiliates and having or asserting authority to require such disclosure in
accordance with that authority or pursuant to the rules of any recognized stock exchange or agency
established in connection therewith, provided, that a Developer making such a disclosure shall make
good faith efforts to advise the other Developers of the same as soon as reasonably practicable,
shall make reasonable efforts to secure protective treatment for the disclosed information and with
respect to any disclosure requirements of any recognized stock exchange, shall cooperate with the
non-disclosing Developer regarding the information to be disclosed;

                    (c) to any Affiliate of a Developer; provided the recipient undertakes to keep such
information or documents under terms of confidentiality equivalent to this ARTICLE 6;

                    (d) to the extent any such information or document has (i) been independently developed by the
recipient, (ii) has been acquired from a third party, or (iii) entered the public domain other than
through the fault or negligence of the Developer making the disclosure (for this purpose any
disclosure by a permitted recipient of a Developer (as aforesaid) shall be deemed to be the fault
or negligence of such Developer);

                    (e) to an arbitration tribunal in connection with resolution of a dispute under this
Agreement; and

                    (f) to the extent permitted under Section 12.8.

          6.2 Use of Confidential Information. Upon termination of the confidentiality period
described in Section 6.3, each Developer shall be entitled to utilize Confidential Information;
provided, however, such utilization shall not include selling, trading or publishing to a third
party such Confidential Information.

          6.3 Survival. The terms of this ARTICLE 6 shall survive the termination of this
Agreement and remain in effect for a period of three (3) years after such termination; provided,
however, that any confidentiality obligations owed by the Developers to any third-party shall
survive for such longer period, if any, as may be specified in the agreement creating such
confidentiality obligation. It is understood that this ARTICLE 6 shall not prohibit, prevent, or
hinder the use of Confidential Information in the development of the Project under this Agreement.

ARTICLE 7

NOTICES

     Except as otherwise specifically provided, all notices authorized or required among the
Developers by any of the provisions of this Agreement, shall be in writing, in English, and delivered in person or by courier service or by any electronic means of transmitting written
communications which provides written confirmation of complete transmission, and addressed to

19

 

such
Developers as designated below. Oral communication does not constitute notice for purposes of this
Agreement, and telephone numbers for the Developers are listed below as a matter of convenience
only. The originating notice given under any provision of this Agreement shall be deemed delivered
only when received by the Developer to whom such notice is directed, and the time for such
Developer to deliver any notice in response to such originating notice shall run from the date the
originating notice is received. The second or any responsive notice shall be deemed delivered when
received, which for purposes of this ARTICLE 7 shall mean actual delivery of the notice to the
address of the Developer to be notified specified in accordance with this ARTICLE 7. Each
Developer shall have the right to change its address at any time and/or designate that copies of
all such notices be directed to another person at another address, by giving written notice thereof
to the other Developers.

	 	 	 
	If to AEI:

	 	Ashmore Energy International
	 

	 	c/o AEI Services LLC
	 

	 	1221 Lamar Street, Suite 800
	 

	 	Houston, Texas 77010
	 

	 	ATTN: General Counsel
	 
	 	 
	With a copy to:

	 	Mr. Brian Bradshaw
	 

	 	Fulbright & Jaworski L.L.P.
	 

	 	Fulbright Tower
	 

	 	1301 McKinney, Suite 5100
	 

	 	Houston, Texas 77010
	 
	 	 
	If to SES:

	 	Synthesis Energy Systems, Inc.
	 

	 	6330 West Loop South, Suite 300
	 

	 	Houston, Texas 77401
	 

	 	ATTN: Chief Executive Officer
	 
	 	 
	With a copy to:

	 	Mr. Robert Reedy
	 

	 	Porter & Hedges
	 

	 	1000 Main, 36th Floor
	 

	 	Houston, Texas 77002

ARTICLE 8

REPRESENTATIONS AND WARRANTIES

     8.1 Representations. Each Developer hereby (a) represents and warrants to the other
Developer the following as of the Effective Date hereof and (b) covenants to the other Developer
that at all times thereafter during the Term of this Agreement that it will cause the following representations and warranties to be true and correct in all material respects
except

20

 

 that, to the extent that any such representation and warranty is qualified by materiality,
such representation and warranty shall be true and correct in all respects:

          8.1.1 It is a duly organized, validly existing entity of the type described in the preamble to
this Agreement and (if applicable) is in good standing under the laws of the jurisdiction of its
formation and is duly qualified to do business and (if applicable) in good standing as a foreign
corporation in the jurisdiction of its principal place of business (if not formed in that
jurisdiction). It has all requisite power and authority to enter into and to perform its
obligations under this Agreement and has obtained (to the extent applicable law permits the
obtaining of same at this point in time) all approvals from applicable governmental authorities
necessary for it to enter into and to perform its obligations under this Agreement.

          8.1.2 Its execution, delivery, and performance of this Agreement have been duly authorized by
all necessary action on its part and that of its equity owners, and do not and will not (a) violate
any law, rule, regulation, order, or decree applicable to it or (b) violate its organizational
documents.

          8.1.3 This Agreement is a legal and binding obligation of that Developer, enforceable against
that Developer in accordance with its terms, except to the extent enforceability is modified by
bankruptcy, reorganization and other similar laws affecting the rights of creditors generally and
by general principles of equity.

          8.1.4 There is no litigation pending or, to the best of its knowledge, threatened to which
that Developer or any of its Affiliates is a party that could reasonably be expected to have a
material adverse effect on the financial condition, prospects, or business of that Developer or its
ability to perform its obligations under this Agreement.

          8.1.5 The execution, delivery and performance of this Agreement will not conflict with,
violate or breach the terms of any agreement of that Developer or of any agreement to which its
properties are subject.

          8.1.6 It is not, and shall not become, a person or entity with whom the other Developer is
restricted from doing business with under the regulations of the Office of Foreign Asset Control
(“OFAC”) of the Department of the Treasury (including, but not limited to, those named on
OFAC’s Specially Designated and Blocked Persons list) or under any statute, executive order
(including, but not limited to, the September 24, 2001, Executive Order Blocking Property and
Prohibiting Transactions With Persons Who Commit, Threaten to Commit, or Support Terrorism), or
other action of any governmental authority.

          8.1.7 It will not attempt to assign, transfer, enter into a Disposition of a Participating
Interest or any rights or obligations under this Agreement, or attempt to develop any Prospective
Project or Project with respect to any third party identified in the U.S. Department of Treasury’s
Excluded Parties Lists System at http://www.epls.gov/.

     8.2 Compliance with Law.

          8.2.1 Each Developer, with respect to itself and its Affiliates, hereby (a) represents and
warrants the following to the other Developer as of the Effective Date hereof and 

21

 

(b) covenants to
the other Developer that at all times thereafter during the Term of this Agreement that it will
cause the following representations and warranties to be true and correct in all material respects
except that, to the extent that any such representation and warranty is qualified by materiality,
such representation and warranty shall be true and correct in all respects:

               (a) It has conducted its affairs and activities in respect of this Agreement in accordance
with applicable laws in all material respects;

               (b) It has not, and covenants and agrees that its employees, agents, consultants, advisors,
representatives or other similar relationships (“Representatives”) will not, in connection
with the purpose or any transactions contemplated by this Agreement, make, promise or offer to make
any payment or transfer of anything of value, directly or indirectly: (i) to any Government
Official or to an intermediary for payment to any Government Official; or (ii) to any political
party. Each Developer further covenants and agrees that neither it nor any of its Representatives
will make, in connection with the purpose or any transactions contemplated by this Agreement, any
payments or transfers of anything of value, directly or indirectly, for the purpose or effect of
public of commercial bribery, acceptance of or acquiescence in extortion, kickbacks or other
unlawful or improper means of obtaining or retaining business or securing any improper advantage.
This Section 8.2.1 shall not, however, prohibit normal and customary business mementos of nominal
value in connection with the Developers’ performance under this Agreement;

               (c) No ownership or profit sharing interest, direct or indirect, in the Developer, or in the
contractual relationship established by this Agreement, is held or controlled by or for the benefit
of any Government Official or representative of a political party (except to the extent that such
Government Official or representative of a political party acquired such interest on a national
recognized exchange), and that the Developer will immediately notify the other Developer in the
event of a change in the foregoing; and

               (d) It has not taken any action that would subject either Developer or any Project Company to
liability or penalty under any applicable law, rules, regulations or decrees of any governmental
authority.

          8.2.2 Each Developer agrees that should it learn or have reason to know of: (a) any payment,
offer, or agreement to make a payment to a Government Official or political party for the purpose
of obtaining or retaining business or securing any improper advantage for the Developer in
connection with this Agreement or otherwise, or (b) any other development during the term of the
Agreement that in any way makes inaccurate or incomplete the representations, warranties and
certifications of the Developers set forth in this Section 8.2, it will immediately advise the
other in writing.

          8.2.3 In order to verify compliance with the provisions of this Agreement and/or any other
agreement signed between the Developers, the Developers agree that each Developer shall have the
right, from time to time, upon written notice to the other Developer, to audit the
books and records of the other to the extent such books and records relate to the performance
of this Agreement and any payments made under this Agreement. Each Developer agrees to

22

 

furnish
promptly to the other Developer any additional information that may reasonably be requested to
verify compliance with the provisions herein.

          8.2.4 The Developers agree that full disclosure of information relating to this Agreement,
including the compensation provisions, may be made at any time and for any reason to the U.S.
government and the respective jurisdictions of the operating businesses, its agencies, and to any
other person, to either Developer, as applicable; provided that the Developer disclosing such
information shall, to the extent permitted by applicable law, notify the other Developer of such
disclosure and the information disclosed.

     8.3 Intellectual Property. SES hereby (a) represents and warrants the following to
AEI as of the Effective Date hereof and (b) covenants to the other Developer that at all times
thereafter during the Term of this Agreement that it will cause the following representations and
warranties to be true and correct in all material respects except that, to the extent that any such
representation and warranty is qualified by materiality, such representation and warranty shall be
true and correct in all respects: (i) it is not aware of any prior art which would invalidate any
claims of any patents owned by SES or any of its Affiliates related to the U-GAS Technology, (ii)
it is not aware of any third party’s patent or patents which have been or would be infringed by the
use or sale of the U-GAS Technology, (iii) neither SES nor any of its Affiliates have received any
assertions from others that the claims of any patents owned by SES or any of its Affiliates are
invalid or unenforceable or that the U-GAS Technology infringes any patents, copyrights, trade
secret rights or other intellectual property rights of others, (iv) it is not aware of any actions
or inactions which would render unenforceable any claims of any patents related to U-GAS Technology
owned by SES or any of its Affiliates, (v) pursuant to that certain Amended and Restated License
Agreement by and among SES and GTI dated August 31, 2006, SES has an exclusive license to
manufacture, make, use and sell U-GAS Technology worldwide, and (vi) neither the entry into this
Agreement nor the granting of a license or sub-license by SES to AEI, any of AEI’s Affiliates, any
Holding Company or any Project Company requires the consent or approval of any third party,
including but not limited to GTI.

ARTICLE 9

DEFAULT AND TERMINATION

     9.1 Event of Default. A Developer shall be in default hereunder if, at any point
during the Term of this Agreement, it is in breach of any of the representations, warranties or
covenants made by such Developer in accordance with ARTICLE 8. If a Developer becomes aware of a
default hereunder by the other Developer, it shall notify the other Developer in writing of such
default. The non-defaulting Developer shall have the right to terminate this Agreement if the
defaulting Developer fails to remedy its default hereunder within forty-five (45) days of receipt
of the written notice of default provided by the non-defaulting Developer in accordance with this
Section 9.1.

     9.2 Additional Events of Default. In addition to any other termination rights provided
in this Article 9, the circumstances set forth below shall give rise to the right for either
Developer to terminate this Agreement. The non-defaulting Developer shall have the right to
terminate this Agreement if the defaulting Developer fails to remedy its default hereunder within

23

 

forty-five (45) days of receipt of the written notice of default provided by the non-defaulting
Developer in accordance with this Section 9.2.

          9.2.1 The Bankruptcy of the other Developer. For purposes of this Section 9.2.1,
“Bankruptcy” shall mean, with respect to any Developer, (a) such Developer’s suspension of
payment of, or request from any court of a moratorium on payment of, all or a substantial part of
such Developer’s debts, (b) such Developer’s making of a general assignment or any composition with
or for the benefit of its creditors, (c) any filing or consent by answer or otherwise by such
Developer to the filing against it of a petition for relief or reorganization or arrangement or any
other petition in bankruptcy, for liquidation or to take advantage of any bankruptcy, insolvency,
reorganization, moratorium or other similar law of any jurisdiction, or (d) any order: (i) entered
for the winding up, bankruptcy, liquidation, dissolution, custodianship or administration with
respect to such Person or any substantial part of such Developer’s property, or (ii) constituting
an order for relief, or (iii) approving a petition for relief or reorganization or any other
petition in bankruptcy or insolvency law of any jurisdiction, or (iv) approving any petition filed
in bankruptcy or insolvency law of any jurisdiction against such Developer;

          9.2.2 The failure by any Developer to pay an amount not in dispute in excess of $500,000.00;

          9.2.3 The occurrence of any change, circumstance or event that would materially hinder a
Developer’s ability to consummate the transactions contemplated by this Agreement; and

          9.2.4 Any Developer or any Affiliate of any Developer is in breach of any representation or
warranty, or otherwise in material breach under any Project Development Agreement (subject to any
cure right set forth in such agreement).

     9.3 Violation of FCPA or OFAC. In the event any Developer is found, through a final
determination made by a Governmental Authority having competent jurisdiction, to be in violation of
the FCPA or any of the restrictions imposed by OFAC, the other Developer shall have the right to
terminate this Agreement immediately by providing a notice thereof setting forth the date of such
termination.

     9.4 AEI Termination Right. AEI shall have the right to terminate this Agreement if the
defaulting Developer fails to remedy its default hereunder within forty-five (45) days of receipt
of the written notice of default provided by the non-defaulting Developer in accordance with this
Section 9.4 if: (a) SES is in breach of its representations or covenants under Section 8.3; (b) SES
or any of its Affiliates is made party to any lawsuit in which an assertion is made by a third
party that the use of the U-GAS Technology infringes any patents, copyrights, trade secret rights
or other intellectual property rights held by any such third party and such lawsuit is not
dismissed within eighteen (18) months of its filing; or (c) with respect to patents related to
U-GAS Technology owned by SES or any of its Affiliates, any claims of such patents are declared
invalid by any court of competent jurisdiction, the United States Patent & Trademark Office or
any patent office of any country in which SES or any of its Affiliates own such patents.

24

 

          9.5 SES Termination Rights.

          9.5.1 SES shall have the right to terminate this Agreement if, within twelve (12) months
following the Effective Date, AEI fails to identify and present to the Project Team at least four
(4) Prospective Projects in any Emerging Markets during such period.

          9.5.2 If AEI or its Affiliates have not purchased 2,000,000 shares of common stock of SES on
or prior to September 15, 2007, SES shall have the right to terminate this Agreement.

ARTICLE 10

APPLICABLE LAW AND DISPUTE RESOLUTION

          10.1 Applicable Law. This Agreement shall be governed by, construed, interpreted, and
applied in accordance with the laws of New York, excluding any choice of law rules which would
refer the matter to the laws of another jurisdiction.

          10.2 Dispute Resolution.

                    10.2.1 Exclusive Procedures and Negotiation in Good Faith. Any dispute, claim, or
controversy arising out of or relating to this Agreement, or the performance, breach, validity,
application, or termination thereof, (“Dispute”) shall be resolved in accordance with the
procedures specified in this Article 10, which shall be the sole and exclusive procedures for the
resolution of any such Disputes.

     In the event of any Dispute, the Developers shall first attempt in good faith to resolve such
Dispute promptly by negotiation between representatives who have authority to settle the Dispute.
Any Developer may give the other Developer written notice of any Dispute not resolved in the normal
course of business in accordance with Article 7. Within 10 business days after delivery of that
notice, the receiving Developer shall submit to the other a written response. Within 30 business
days after delivery of the notice of Dispute, the representatives of the Developers shall meet at a
mutually acceptable time and place, and thereafter as often as they reasonably deem necessary, to
attempt to resolve the Dispute. If a Developer refuses to negotiate as provided herein or if the
Dispute has not been settled within sixty (60) days of the delivery of the notice, any Developer
may immediately initiate arbitration as provided in Section 10.2.3.

                    10.2.2 Agreement to Arbitrate. Any Dispute not resolved by negotiation as provided
above shall be finally resolved by binding arbitration under the Rules of Arbitration
(“Rules”) of the International Chamber of Commerce (“ICC”) by arbitrators appointed
in accordance with the said Rules and this Agreement.

                    10.2.3 Number and Appointment of Arbitrators. The arbitral tribunal shall be composed
of three neutral, independent, and impartial arbitrators (the “Tribunal”). In the request
for arbitration, the Developer requesting arbitration (the “Claimant”) shall nominate one
arbitrator. The other Developer (the “Respondent”) shall nominate one arbitrator within
the time specified in the Rules. The two arbitrators nominated by the Claimant and Respondent
shall together nominate the third arbitrator, who shall be the chairman of the Tribunal, by mutual

25

 

agreement within twenty (20) days of the Respondent’s appointment of the second arbitrator. If any
nominated arbitrator is not appointed, declines, resigns, becomes incapacitated, or otherwise
refuses or fails to serve or to continue to serve as an arbitrator, the party or arbitrators
entitled to nominate that arbitrator shall promptly nominate a successor. Should a party fail to
nominate an arbitrator, or should the two party appointed arbitrators fail to nominate a chairman,
the ICC shall make the appointment.

          10.2.4 Venue; Procedural Issues. The seat of the arbitration shall be Houston, Texas.
The arbitration shall be conducted and the award rendered solely in the English language. The
Developers agree that in matters of disclosure and evidence in the arbitration, the Tribunal shall
be guided by the Rules On the Taking of Evidence in International Commercial Arbitration of the
International Bar Association. Subject to any relevant legal privilege against disclosure, the
Tribunal shall have the power to make all appropriate orders necessary for disclosure, which orders
the Developers consent in advance to obey.

          10.2.5 Powers of the Arbitrators; Limitations On Remedies. The validity,
construction, and interpretation of this agreement to arbitrate, and all procedural aspects of the
arbitration conducted pursuant to this agreement to arbitrate, shall be decided by the Tribunal.
The Tribunal shall have the power to award all remedies available under the applicable law except
that the Tribunal shall have no power to award any consequential, punitive, or special damages and
shall have no power to rely on the applicable law to avoid this limitation, regardless of whether
such excluded remedies would be available under the applicable law. The Tribunal shall not decide
the Dispute by reliance on any other doctrine or principle that would permit the Tribunal to avoid
the application of this Agreement and/or the applicable law. The Tribunal shall also have the power
to enter such interim orders as it deems necessary, including, without limitation, orders to
preserve the subject matter of the Dispute or to preserve or adjust the status of the parties
pending resolution of the Dispute in arbitration.

          10.2.6 Arbitration Awards. The Tribunal shall expedite all procedures and take all
reasonable efforts to expedite an award. The award shall be in writing and shall give reasons for
the decisions reached by the Tribunal. A copy of the award shall be contemporaneously delivered to
each of the Developers. The Developer against which an award assesses a monetary obligation or
enters an injunctive or mandatory order shall pay that obligation or comply with that order on or
before the thirtieth (30th) day following the receipt of the final, signed award or by
such other date as the award may provide. The award shall be final and binding on the Developers
and may be confirmed in, and judgment upon the award entered by, any court having jurisdiction over
the Developers. The Tribunal’s award shall be entitled to all of the protections and benefits of a
final judgment as to any Dispute, shall be final and binding on the Developers and non-appealable
to the maximum extent permitted by law, and each Developer shall be estopped from raising any
claims that such Developer could have presented to the Tribunal during the arbitration. Each
Developer affirmatively waives, to the maximum extent permitted
by applicable law, any right to contest the recognition or enforcement of the award in any
jurisdiction where recognition or enforcement may be sought on the award.

          10.2.7 Confidentiality. Except to the extent necessary for proceedings relating to
enforcement of the arbitration agreement, the award or other, related rights of the parties, the
fact of the arbitration, the arbitration proceeding itself, all evidence, memorials or other
documents

26

 

exchanged or used in the arbitration and the arbitrators’ award shall be maintained in
confidence by the Developers to the fullest extent permitted by applicable law. However, a
violation of this covenant shall not affect the enforceability of this agreement to arbitrate or of
the Tribunal’s award.

          10.2.8 Costs of Arbitration. The Tribunal shall designate a prevailing Developer in
its final award. Pursuant to this determination, the Tribunal shall award to the prevailing
Developer its attorneys’ fees, costs and expenses of the arbitration (including the arbitrators’
fees and expenses) as they deem appropriate.

          10.2.9 Interest. The award shall include interest, which shall run from the date of
any breach or violation of this Agreement, which shall be determined by the Tribunal in its award.
Interest shall continue to run from the date of award until the award is paid in full. Interest
shall be calculated and compounded monthly at the US LIBOR rate as published by the Financial
Times on the first business day of the month plus two and one-half percent (2.5 %).

          10.2.10 Pre-arbitral Referee. Either Developer shall have the right to have recourse
to the Pre-Arbitral Referee Procedure of the ICC in accordance with its Rules for a Pre-Arbitral
Referee Procedure; provided, however, that (i) the answer to the request for a Pre-Arbitral Referee
must be submitted no later than the seventh (7th) day following receipt of such request for a
Pre-Arbitral Referee, (ii) the Referee shall be appointed by the ICC, if possible within seven (7)
business days of the request for Pre-Arbitral Referee, and (iii) the Referee shall issue his order
within ten (10) days of the later of receipt of the answer or his appointment unless exceptional
circumstances require additional time, in which case the Order must be issued within twenty (20)
days of the above dates. The Pre-Arbitral Referee Procedure is without prejudice to the agreement
to arbitrate contained in this Section 10.2.10.

     10.3 No Immunity. To the extent that any Developer may in any jurisdiction claim for
itself, or its assets or revenue, immunity from suit, execution, attachment, or other legal process
with respect to this Agreement, or the performance, nonperformance or breach thereof, and to the
extent that in any such jurisdiction there may be attributed to a Developer, or its assets or
revenues, such immunity (whether or not claimed), each Developer agrees not to claim and hereby
irrevocably waives such immunity to the full extent permitted by the laws of such jurisdiction.

ARTICLE 11

INDEMNIFICATION AND LIABILITY

     11.1 Indemnification and Limitation on Liability.

          11.1.1 Except as provided herein, no Developer or its respective shareholders, directors,
officers, employees, and agents shall have any liability to the other Developer for any loss
suffered by the other Developer arising out of any action or omission by any of them, so long as
such action or omission (a) was in good faith; (b) was consistent with the provisions of this
Agreement; and (c) did not constitute the gross negligence or willful misconduct of the Developer
involved.

27

 

          11.1.2 Each of AEI and SES agree severally (not jointly) to defend, indemnify, and hold
harmless the other Developer, its respective Affiliates and its respective shareholders, directors,
officers, employees and agents (collectively, “Indemnitees”) from and against any losses,
damages, judgments, liabilities, expenses, and amounts paid in settlement of any claims with
respect to death, personal injury, or damage to property of a third party due to the gross
negligence, fraud or willful misconduct of such indemnifying Developer, its Affiliates and their
respective shareholders, directors, officers, employees and agents.

          11.1.3 Each of AEI and SES agree severally (not jointly) to defend, indemnify and hold
harmless the other Developer and its respective Indemnitees from all losses, damages, judgments,
liabilities, expenses, and amounts paid in settlement, that relate to, result from, or are in
connection with, any misrepresentation or breach of any warranty or representation given by such
Developer in this Agreement, or breach of any covenant or agreement made by such Developer in this
Agreement.

          11.1.4 In no event, whether as a result of breach of this Agreement or any resulting contract
therefrom, warranty, indemnity, tort (including negligence), strict liability or otherwise, shall
any Developer be liable to any other Developer for any consequential damages, special or incidental
damages, lost profits, punitive damages, exemplary damages, enhanced damages, multiple damages,
indirect damages, or other penalty or speculative damages arising out of this Agreement.

          11.1.5 SES shall defend, indemnify and hold harmless AEI, each Holding Company, each Project
Company and each of their respective Indemnitees from and against any and all claims of
infringement or misappropriation of patent, copyright, trademark, trade secret rights, confidential
information, proprietary rights or other intellectual property rights based upon the use or sale in
accordance with this Agreement of the U-GAS Technology by AEI or any Project Company.

          11.1.6 A Developer shall notify the other Developers in writing promptly after it becomes
aware of any facts that may lead to the making of a claim for indemnification under this Agreement.
Any amounts owing by a Developer under this ARTICLE 11 shall be due and payable within ten (10)
days of the final resolution of the underlying claim pursuant to this Agreement.

          11.1.7 The provisions of this Section 11.1 shall survive the termination of this Agreement or
the withdrawal of any Developer from the Project.

	           11.2   No Fiduciary Duty. In their relations with each other under this Agreement, the
Developers shall not be considered fiduciaries, and each Developer agrees not to assert any
claim that the Developers are fiduciaries. Without in any way limiting the foregoing, each
Developer may grant or withhold its consent, approval or vote, in its sole discretion, without
regard to the interests of or any obligation to the other Developer or its subsidiaries, it being
understood that neither Developer has any fiduciary or other express or implied duty to represent
or act in the best interests of the other Developer. The provisions of this Section 11.2 shall
survive the termination of this Agreement or the withdrawal of any Developer from the Project.

28

 

     11.3 Non-Recourse. The obligations of the Developers under this Agreement are
obligations of the Developers only, and no recourse shall be available against any officer,
director, or equity holder.

ARTICLE 12

MISCELLANEOUS

     12.1 Relationship of the Developers. The Developers understand and agree that none of
the Developers is an agent, employee, contractor, vendor, or representative of the other Developer,
and that they shall not hold themselves out as such to third parties. Nothing in this Agreement is
intended to create any partnership or other association among the Developers. The rights, duties,
obligations, and liabilities of the Developers under this Agreement shall be several and not joint
or collective and shall be borne by each as set forth herein.

     12.2 Integration. Subject to any Project Development Agreement to the contrary, the
terms and provisions contained in this Agreement constitute the entire agreement among the
Developers with respect to the subject matter hereof. This Agreement supersedes and terminates all
previous undertakings, representations and agreements, both oral and written, between or among any
of the Developers with respect to the Project. In the event of a conflict between the terms hereof
and the terms of a Project Development Agreement, the terms of the Project Development Agreement
shall prevail.

     12.3 No Oral Modifications. This Agreement may not be amended or modified except by
written agreement signed by each of the Developers.

     12.4 Effective Date; Term. This Agreement shall be effective on the Effective Date and
shall have a term of sixty (60) months unless terminated early by either Developer pursuant to the
provisions hereof or by mutual agreement of the Developers (the “Term”); provided, however,
that if the Effective Date has not occurred on or before July 13, 2007, this Agreement shall
automatically be terminated without liability to any party and shall be of no further force or
effect. Notwithstanding the foregoing, (a) the obligations of the parties hereunder related to
indemnity and confidentiality shall survive for a period of three (3) years
following the expiration or early termination hereof, and (b) this Agreement, including all
obligations of the parties related thereto, shall survive with respect to any Project that has been
presented to the Project Team prior to the expiration or early termination of this Agreement.
Without prejudice to the foregoing, SES shall have no further obligation to provide Project Support
services to any Project after the expiration of twenty four (24) months following the termination
of this Agreement.

     12.5 Headings. Titles and headings of all Articles and Sections of this Agreement are
for convenience of reference and do not form a part of this Agreement and shall not in any way
affect the interpretation of the Agreement.

     12.6 Waiver. The waiver of any breach of any of the terms or conditions hereof shall
not be deemed a waiver of any other or subsequent breach, whether of a like or different nature.
No failure to exercise and no delay in exercising, on the part of a Developer, any right,

29

 

power, or
privilege hereunder shall operate as a waiver thereof, nor shall any single or partial exercise of
any right, power or privilege hereunder preclude any other or further exercise thereof.

     12.7 Counterparts. This Agreement may be executed in more than one counterpart, each
of which shall be deemed to be an original, and all of which together shall constitute one and the
same document.

     12.8  Public Announcements. No Developer may make or issue any press release, public
announcement, or statement regarding this Agreement or the Project without the consent of the other
Developer, which consent shall not be unreasonably withheld. However, no such consent shall be
required if a Developer is required to issue or make any press release, public announcement, or
statement by applicable law or judicial proceeding, or by governmental order, decree, regulation or
rule, or by the listing requirements of the stock exchange on which a Developer or any of its
Affiliates is listed; provided, however, that a Developer making such a required disclosure shall
make good faith efforts to advise the other Developers of the same as soon as reasonably
practicable. The Developers shall cooperate to establish a public affairs program to pre-approve
announcements, answer questions, and draft statements that may be used by the Developers in
connection with the Project. Notwithstanding any provision herein to the contrary, no party shall
have the right to make reference to, or otherwise use the name of the other party without the prior
written consent of such party.

     12.9 Counterparts. Each Developer is represented by its own outside counsel and shall bear
its own costs in relation to the negotiation, preparation, and execution of this Agreement.

[The remainder of this page intentionally left blank]

30

 

     IN WITNESS WHEREOF, the Developers have caused this Agreement to be executed by their duly
authorized officers as of the day and year first above written.

	 	 	 	 	 	 	 
	 	 	ASHMORE ENERGY INTERNATIONAL	 	 
	 
	 	 	 	 	 	 
	 

	 	By:
	 	/s/ James Hughes	 	 
	 

	 	 	 	 	 	 
	 

	 	 	 	Name: James Hughes

Title: Chief Operating Officer
	 	 
	 
	 	 	 	 	 	 
	 	 	SYNTHESIS ENERGY SYSTEMS, INC.	 	 
	 
	 	 	 	 	 	 
	 

	 	By:
	 	/s/ Timothy E. Vail	 	 
	 

	 	 	 	 	 	 
	 

	 	 	 	Name: Timothy E. Vail

Title: President and Chief Executive Officer	 	 

S-1

 

Exhibit “A”

Project Description

Project Description

Describe the summary features of the transaction including:

	 	o	 	Project background/history
	 
	 	o	 	Counterparty (s) involved in the proposed project
	 
	 	o	 	Summary of terms and major issues
	 
	 	o	 	Study of target market

Initial Project Economics

Provide a summary valuation and return analysis that includes:

	 	o	 	Discounted cash flow analysis
	 
	 	o	 	Major value drivers and assumptions
	 
	 	o	 	Descriptions and results of sensitivities

Provide initial financial projections

	 	o	 	Income statement
	 
	 	o	 	Balance sheet
	 
	 	o	 	Cash flow statement
	 
	 	o	 	Any other relevant information (fees, royalties, etc)

Key Risks and Mitigants

Provide an overview of material transaction risks and potential mitigants, including those related to :

	 	o	 	Permitting and approvals
	 
	 	o	 	Market pricing and demand
	 
	 	o	 	Construction and operations
	 
	 	o	 	Tax, accounting, and financing

Project Milestones 

Proposed Lead Developer for the Project

Outline key milestones and events up to closing:

	 	o	 	Timing of expected contract discussions, licenses or site
acquisitions, and other key project stages
	 
	 	o	 	Future decision points, approvals, and all other material events

Budget and Resources

Provide detailed project development budget and required resources that includes:

	 	o	 	Estimated cost of all internal and external resources
	 
	 	o	 	Estimated timing of cash expenditures

A-1

 

Exhibit “B”

FORM OF

PROJECT DEVELOPMENT AGREEMENT

by and among

[ASHMORE ENERGY INTERNATIONAL]

And

[SYNTHESIS ENERGY SYSTEMS, INC.]

Dated as of

___, 20___

B-1

 

PROJECT DEVELOPMENT AGREEMENT

(__________ Project)

     This Project Development Agreement, dated as of ___, 20___, is made by and among
[ASHMORE ENERGY INTERNATIONAL], a company formed under the laws of the [Cayman Islands]
(“AEI”), and [SYNTHESIS ENERGY SYSTEMS, INC.], a company formed under the laws of
[Delaware] (“SES”). AEI and SES are sometimes hereinafter referred to individually as a
“Developer” and collectively as the “Developers.”

BACKGROUND

     Pursuant to the Joint Development Agreement, the Developers wish to undertake jointly the
development of the project described in Exhibit A (the “Project”). This Agreement sets forth the
terms and conditions under which the Developers agree to develop the Project, and other matters
related thereto.

     NOW, THEREFORE, in consideration of the matters described above, the representations,
warranties and covenants in this Agreement, and other good and valuable consideration, the receipt
and sufficiency of which are hereby acknowledged, the Developers agree as follows:

ARTICLE I

DEFINITIONS

     The following terms, when used herein, shall have the meanings set forth below. The meanings
specified are applicable both to the singular and the plural and to the masculine and feminine
forms. In addition, throughout this Agreement, the word “includes” or “including” shall mean
“including without limitation”.

     1.01 “AEI” has the meaning ascribed to such term in the preamble.

     1.02 “Affiliate” means, with respect to any Person, any other Person directly or indirectly
(through one or more intermediaries) controlling, controlled by or under common control with such
Person, and for such purposes the term “control” shall mean the direct or indirect ownership of
more than fifty percent (50%) of the total outstanding voting powers or equity securities of, or
other ownership interests in, a Person.

     1.03 “Agreement” means this Project Development Agreement, together with the exhibits and
other attachments hereto, which are incorporated by reference herein and made a part hereof, as
amended or modified from time to time.

     1.04 “Authorizations” means any consent, license, approval, permit, or other authorization of
whatsoever nature that is required to be granted by any Governmental Authority:

     (a) for the formation of the Project Company and the making by it of the payments
contemplated by the Project Contracts, the Financing Agreements, or the Equity Subscription
Agreements;

B-2

 

     (b) for the making of the payments contemplated to be made under this Agreement;

     (c) for the construction, operation, and maintenance of the Project; and

     (d) for all such other matters that may be necessary in connection with the Project or
the performance of the Project Company’s or the Developers’ and their Affiliates’
obligations under this Agreement, the Project Contracts, the Financing Agreements, or the
Equity Subscription Agreements.

     1.05 “Bankruptcy” has the meaning ascribed to such term in Section 11.02(a).

     1.06 “Claimant” has the meaning ascribed to such term in Section 8.03.

     1.07 “Co-Developer” means each Developer that is not the Lead Developer.

     1.08 “Confidential Information” has the meaning ascribed to such term in Section 7.04.

     1.09 “Cost-Sharing Percentages” has the meaning ascribed to such term in Section 4.02(a).

     1.10 “Developer” and “Developers” have the meanings ascribed to such terms in the preamble to
this Agreement.

     1.11 “Development Budget” means the budget attached to this Agreement as Exhibit D, as it may
be revised as provided in Section 2.04.

     1.12 “Development Costs” means External Development Costs and Internal Development Costs.

     1.13 “Dispute” has the meaning ascribed to such term in Section 8.01.

     1.14 “Dollars” or “$” means the lawful currency of the United States of America.

     1.15 “EPC Contract” means the agreement or agreements under which one or more contractors will
design, procure, construct, complete, test, commission, and remedy defects in the Project.

     1.16 “Equipment” shall mean all materials, supplies, equipment, spare parts and facilities, of
whatever nature, intended to become a permanent part of the Project, including without limitation
any of the foregoing that utilize all or any part of the U-Gas Technology.

     1.17 “Equipment Supply Agreement” means any agreement to provide, supply or sell Equipment to
the Project.

     1.18 “Equity Owner” means a Person owning shares, partnership interests, or other equity
interests in the Project Company.

B-3

 

     1.19 “Equity Subscription Agreement” means any agreement that may be entered into in
connection with the Financing Agreements or otherwise, under which a Developer is to subscribe for
additional shares to contribute additional capital to the Project Company, or to lend or otherwise
advance funds to the Project Company.

     1.20 “External Development Costs” means all actual, reasonable, direct and necessary costs and
expenses incurred by a Developer with third party contractors and service providers during the Term
for the evaluation, research, study, development or implementation of the Project, including
without limitation transportation, lodging, courier, telecommunication and reproduction costs,
consultant/advisor fees, Internal Engineering Support, External Engineering Support, Training and
Technical Support.

     1.21 “External Engineering Support” shall mean engineering support services provided by SES to
the Project using third-party personnel that has been contracted and compensated by SES, which
services shall include, without limitation, design, engineering and process requirements; design
and process methodology (including underlying engineering methods), design and process philosophy,
component features; engineering experience, engineering analysis, processing, operations and
construction know-how, including the processing, operations and construction techniques and
processes needed for coal regasification.

     1.22 “FCPA” means the United States Foreign Corrupt Practices Act of 1977 (15 U.S.C. §§
78dd-1, et seq.), as amended.

     1.23 “Final Investment Decision” means, with respect to the Project, the decision by the board
of directors of the Project Company to proceed with the Project as demonstrated by the approval to
(a) fund the equity required to develop the Project, (b) issue full notice to proceed under the EPC
Contracts, (c) execute any Project Contracts not yet executed, and perform under all Project
Contracts, or (d) execute, deliver and perform any Financing Agreements and material related
documents required for the development of the Project.

     1.24 “Financing Agreement” means each or any of:

     (a) the Project Company’s agreements with other Persons for the provision to the
Project Company of loans, credit facilities or other funds (other than by way of equity
participation) for the design, construction, and procurement of Equipment for the Project
and any term financing to replace any such prior financings; and

     (b) the security documents, direct agreements, and other ancillary undertakings in
favor of Lenders or their designees required pursuant to the agreements referred to in
clause (a) above.

     1.25 “Force Majeure” has the meaning given that term in Section 10.02.

     1.26 “Fuel Management Agreement” means the agreement or agreements under which the Project
Company will appoint an agent to negotiate the fuel supply arrangements for the Project and to
manage the procurement, transportation, nomination, and transmission to the Project’s site of
supplies of coal required for the commissioning and the operation of the Project.

B-4

 

     1.27 “Fuel Supply Agreement” means the agreement or agreements under which other Persons agree
to sell and the Project Company agrees to buy, or other Persons agree to transport for the Project
Company, any fuels to be used by the Project.

     1.28 “GTI” means the Gas Technology Institute, a research, development and training
organization serving the natural gas industry and energy markets.

     1.29 “ICC” means the International Chamber of Commerce.

     1.30 “Governmental Authority” means any government, political subdivision, court or any
agency, instrumentality, or authority thereof.

     1.31 “Government Official” means any employee or officer of a Governmental Authority, any
official of a political party, any official or employee of a public international organization, any
person acting in an official capacity for, or on behalf of, such entities, and any candidate for
foreign political office.

     1.32 “Indemnitees” has the meaning ascribed to such term in Section 9.04(b).

     1.33 “Internal Development Costs” means the wages and salaries of a Developer’s employees and
internal personnel who are directly engaged in the evaluation, research, study, development or
implementation of the Project, at rates to be agreed by the Developers.

     1.34 “Internal Engineering Support” means engineering support services provided by SES to the
Project using SES employees and internal personnel that has been contracted and compensated by SES,
engineering support services that shall include, without limitation, design, engineering and
process requirements; design and process methodology (including underlying engineering methods),
design and process philosophy, component features; engineering experience, engineering analysis,
processing, operations and construction know-how, including the processing, operations and
construction techniques and processes needed for coal regasification.

     1.35 “Joint Development Agreement” means the Joint Development Agreement entered into between
AEI and SES on July ___, 2007, whereby they agree to undertake jointly the development of coal
conversion projects utilizing the U-Gas Technology.

     1.36 “Lead Developer” has the meaning ascribed to such term in Section 2.03.

     1.37 “Lenders” means the Persons providing loans or credit under the Financing Agreements or a
trustee or agent acting for them.

     1.38 “OFAC” has the meaning ascribed to such term in Section 9.01(f).

     1.39 [“Offtaker” means the Person that is the purchaser under the Offtake Agreement, and any
successor to it.]

     1.40 [“Offtake Agreement” means the agreement for the sale by the Project Company and the
purchase by the Offtaker of the output of the Project.]

B-5

 

     1.41 “Operating and Maintenance Agreement” means the agreement under which an operating
company will provide operating and maintenance services to the Project Company in connection with
the Project.

     1.42 “Person” includes any natural person, corporation, company, partnership (general or
limited), limited liability company, business trust, Governmental Authority, or other entity or
association.

     1.43 “Project” has the meaning given that term under the heading “Background” above.

     1.44 “Project Company” has the meaning given that term in Section 4.01.

     1.45 “Project Contract” means any of the following agreements to which the Project Company
will be a party:

     (a) [the Offtake Agreement;]

     (b) the EPC Contract;

     (c) the Fuel Management Agreement;

     (d) [the Fuel Supply Agreement;]

     (e) the Operating and Maintenance Agreement

     (f) [the Site Acquisition Agreement;]

     (g) the Equity Subscription Agreement;

     (h) the Equipment Supply Agreement;

     (i) any other agreement with any other Person for the construction, operation, or
maintenance of the Project, gas sales from the Project, technology licenses, technical
support arrangements, or fuel supply or transportation to the Project, or for the supply of
other goods or services essential to the Project, in each case calling for payments in the
aggregate in excess of $___(or the equivalent in the applicable currency) or having a
maximum term of greater than six (6) months.

     1.46 “Project Country” means ___.

     1.47 “Project Site” means the parcel of land upon which the Project shall be located in
___.

     1.48 “Referee” has the meaning ascribed to such term in Section 8.10.

     1.49 “Respondents” has the meaning ascribed to such term in Section 8.03.

     1.50 “Rules” has the meaning ascribed to such term in Section 8.02.

B-6

 

     1.51 “SES” has the meaning ascribed to such term in the preamble.

     1.52 [“Site Acquisition Agreement” shall mean the agreement(s) pursuant to which title to the
Project Site shall be acquired or a leasehold interest or other right of beneficial use of the
Project Site shall be obtained.]

     1.53 “Shareholders Agreement” means the agreement by which the Equity Owners set forth their
rights and obligations with respect to their equity interests in the Project Company.

     1.54 “Specified Rate” means, for any period for which interest is to be calculated, the per
annum rate equal to the lesser of (a) a rate of interest per annum for each day during that period
equal to two point five percent (2.5%) per annum over the three-month London Interbank Offered Rate
for dollars quoted in The Wall Street Journal for that day (or if not published that day, the next
preceding day on which it is published), or if a range is quoted, the midpoint of that range or (b)
the maximum rate permitted by applicable law.

     1.55 “Technical Support” shall mean technical support for the operation and maintenance of
Equipment, components, facilities, systems, subsystems, auxiliaries and accessories utilizing all
or any part of the U-Gas Technology.

     1.56 “Term” has the meaning ascribed to such term in Section 12.03.

     1.57 “Termination Date” has the meaning ascribed to such term in Section 6.01.

     1.58 “Training” shall mean orientation, education and instruction in the use, implementation
and operation of the Equipment and the U-Gas Technology intended to become a permanent part of the
Project, including without limitation the following:

     (a) instruction and education, in amounts and at times to be agreed by the Developers,
regarding the start-up, operation, shutdown and maintenance of Equipment, components,
facilities, systems, subsystems, auxiliaries and accessories utilizing all or any part of
the U-Gas Technology;

     (b) manuals, diagrams, drawings, checklists, and other written information regarding
the start-up, operation, shutdown and maintenance of Equipment, components, facilities,
systems, subsystems, auxiliaries and accessories utilizing all or any part of the U-Gas
Technology;

     (c) written identification of necessary and desirable short and long term spare part
inventories, maintenance supplies, special tools and Equipment for the Project;

     (d) emergency procedures for the Project, including with regards to Equipment,
components, facilities, systems, subsystems, auxiliaries and accessories utilizing all or
any part of the U-Gas Technology; and

     (e) safety procedures and precautions for the Project, including with regards to
Equipment, components, facilities, systems, subsystems, auxiliaries and accessories
utilizing all or any part of the U-Gas Technology.

B-7

 

     1.59 “Tribunal” has the meaning ascribed to such term in Section 8.03.

     1.60 “U-Gas Technology” means a process involving conversion of coal to fuel gas by reaction
of coal with air at over 75 psia with the addition of steam, carbon dioxide or other diluent gases
in a fluidized bed reactor system with a sloping grid and central nozzle in which high carbon
conversion is obtained by utilizing techniques with or without ash agglomeration with control of
ash sintering and the withdrawal of high ash material or agglomerates, wherein crushed coal is fed
directly into the fluidized bed with recycle of coal dust or char fines entrained in effluent gas
back into the fluidized bed.

     1.61 “United States” or “U.S.” means the United States of America.

Unless otherwise provided, when used in this Agreement: all references to “Articles” and “Sections”
are to Articles and Sections of this Agreement; all references to “Exhibits” are to Exhibits
attached to this Agreement, each of which is made a part of this Agreement for all purposes; and
the words “hereof,” “herein,” and “hereunder” refer to this Agreement as a whole and not to any
particular provision of this Agreement. References to any gender include all others if applicable
in the context. Terms defined in the singular shall have the corresponding meaning when used in
the plural and vice versa. All uses of “include” or “including” mean “without limitation”.
References to a law, rule, regulation, contract, agreement, or other document mean that law, rule,
regulation, contract, agreement, or document as amended, modified, or supplemented, if applicable.
Any definition of one part of speech of a word, such as definition of the noun form of that word,
shall have a comparable meaning when used as a different part of speech, such as the verb form of
that word.

ARTICLE II

DEVELOPMENT ACTIVITIES

     2.01 Development Generally. On and subject to the terms set forth in this Agreement, the
Developers will work together toward the development of the Project. Each Developer (or one or
more of its Affiliates, if appropriate) shall perform the services, cooperate with each other
Developer and its Affiliates, and supply the elements of the Project set forth for that Developer
on Exhibit B.

     2.02 Preliminary Timetable; Development Budget; Cash Call. (a) The Developers shall undertake
the tasks assigned to them on Exhibit C during the periods listed on Exhibit C (which shall include
a timeline for Equipment supply and delivery), subject to adjustment due to the nature of the
development process. The Developers acknowledge that the nature of development of any undertaking
such as the Project is subject to numerous uncertainties; in the case of the Project those
uncertainties include [the lack of an established market, the political and economic environment in
the Project Country, and the state of international capital markets.] Accordingly, steps in the
preliminary timetable may be added, modified, deleted, or rearranged.

     (b) The Developers adopt the Development Budget attached as Exhibit D hereto and agree
to make equity contributions to the Project Company in accordance therewith and with the
Equity Subscription Agreement.

B-8

 

     2.03 Lead Developer. (a) The Developers hereby agree that ___ shall be the Lead Developer
for the Project (the “Lead Developer”). The Lead Developer shall oversee the overall
development of the Project. Except for (i) the work to be performed by each Co-Developer, as
described in Exhibit B, and (ii) decisions requiring the unanimous consent of all the Developers as
set forth in Section 2.04(a), the Lead Developer shall make all decisions regarding, and shall
perform (or shall contract with others to perform) all activities relating to the development of
the Project. The Lead Developer shall keep each Co-Developer informed of development plans and the
status of development and shall consider in good faith suggestions by each Co-Developer regarding
the Project’s development.

     (b) The Lead Developer will lead the negotiation of the Project Contracts and the
Financing Agreements, other than Project Contracts to which the Lead Developer or its
Affiliates are parties, and will obtain all Authorizations required to develop the Project,
as well as take any and all other actions necessary and convenient for the development,
construction, financing, operation and maintenance of the Project in accordance with the
terms of this Agreement and the Joint Development Agreement.

     (c) Each Developer will be informed and consulted by each other Developer
regarding decisions, development plans and the status of development of the Project.
Such Developer will, where practicable, be invited to all negotiations and meetings
regarding the Project Contracts and to meetings regarding other matters relating to
the Project. Each Developer shall have the right to bring those advisors,
consultants or representatives as it deems necessary to any such meeting.

     (d) Neither a Developer nor an Affiliate of a Developer may take any action purporting
to bind the Project Company, any other Developer, or its Affiliates, except as provided in
this Agreement, the Joint Development Agreement and the Project Contracts. All actions
undertaken by the Developers and their Affiliates, or any of them, are at their sole risk
and expense except to the extent, if any, that the Project Company assumes those obligations
by executing Project Contracts, Financing Agreements, or other documents in accordance with
this Agreement or that related Development Costs are reimbursable under Article III. This
Agreement is not intended to create, and shall not be construed as creating, a partnership
or joint venture. None of the Developers is an agent, employee, contractor, vendor,
representative, or partner of any other Developer or its Affiliates, and a Developer may not
hold itself out as such; provided, however, that Developers and their Affiliates may be
parties to Project Contracts and holders of interests in the Project Company.

     2.04 Unanimous Consent. (a) The following actions require consent from all the Developers:

     (i) modifying or supplementing the overall design of the Project or the
Development Budget;

     (ii) approving, amending, or terminating:

B-9

 

     (A) the overall plan for financing the costs of constructing the
Project;

     (B) any of the Project Contracts; or

     (C) any of the Financing Agreements; or

     (iii) abandoning development of the Project.

     (b) The Developers shall be considered to have consented to the actions described in
Section 2.04(a) if:

     (i) All the Developers vote to approve the action at a meeting of
representatives from each Developer called by notice from any Developer to the
others, which notice must specify the date and time of the meeting (which may be no
earlier than the tenth Business Day following the notice) and its location or that
the meeting will be conducted by telephone conference; provided, however, that a
Developer whose representatives attend or participate by telephone in a meeting
shall be deemed to have received timely notice of the meeting; or

     (ii) All the Developers sign a written instrument setting forth the action to
which they are consenting.

     (c) Subject to the other provisions of this Agreement, representatives of the
Developers shall in good faith attempt to resolve any Disputes that may arise between the
Developers under this Agreement or in connection with the development of the Project.
Without prejudice to the foregoing, any Developer may submit a matter to negotiation by
senior representatives of the Developers, in accordance with Section 8.1(b).

     2.05 Reasonable Efforts and Cooperation. The Developers shall use all commercially reasonable
efforts in performing their obligations under this Article II and shall cooperate with one another
fully and in good faith to facilitate the development of the Project in accordance with this
Agreement and the Joint Development Agreement. Each Developer shall abide by the provisions of the
Equity Subscription Agreement or any other agreement relating to voting and transfer of equity
interests in the Project Company, the Project Company’s organizational documents, the Shareholders
Agreement, or similar document, provided, however, that the provisions hereof shall not be
construed as a guarantee of any obligation to pay money or any obligation to perform services.

ARTICLE III

DEVELOPMENT COSTS

     3.01 Development Costs. (a) Each Developer and its Affiliates shall bear, without recourse
to each other Developer or the Project Company, all Development Costs that the Developer and its
Affiliates spend or incur unless and until they are to be reimbursed as provided in Section 3.01(b)
and Section 3.01(c).

B-10

 

     (b) Within ten (10) days of the conclusion of each calendar quarter during the Term,
both prior to and following the formation of the Project Company, each Developer shall
submit and shall cause its Affiliates to submit to the Lead Developer a statement of all
External Development Costs incurred by that Developer during that calendar quarter. As soon
as possible following its receipt of such statement, the Lead Developer shall prepare and
circulate to each Developer a schedule that calculates (i) the total External Development
Costs incurred by each Developer during the preceding quarter, and (ii) the reimbursements
(if any) required to be provided by one Developer to any other Developer in order to ensure
that each Developer bears External Development Costs in proportion to its respective Cost
Sharing Percentage. Each Developer required to reimburse any other Developer pursuant to
such schedule shall do so within thirty (30) days from its receipt of such schedule.

     (c) In connection with the Final Investment Decision for the Project, each Developer
shall submit and shall cause its Affiliates to submit to the Project Company a statement of
all Internal Development Costs and External Development Costs that such Developer and its
Affiliates have incurred for the Project through the Final Investment Decision, to the
extent such External Development Costs have not been previously reimbursed in accordance
with Section 3.01(b). Each Developer shall cause the Equity Owners of the Project Company
to cause the Project Company to reimburse all outstanding Development Costs to the Developer
that incurred them, together with interest thereon calculated from the date incurred until
the date of reimbursement at the Specified Rate, to the extent permitted by the Financing
Agreements.

     3.02 Guarantees. If a Developer or an Affiliate of a Developer guarantees debt of the Project
Company prior to the Final Investment Decision to enable the Project Company to pay obligations
that, if incurred by a Developer, would be External Development Costs eligible for reimbursement
under this Article III, and if that Developer or Affiliate makes a payment under that guarantee,
each other Developer shall reimburse to the Developer or Affiliate making the payment, on demand,
its Cost-Sharing Percentage of the payment, plus interest at the Specified Rate from the date the
payment on the guarantee was made until the reimbursement is made.

     3.03 Bid Bonds and Other Liability. The obligations of the Developers under any bid bonds,
development bonds or guarantees required to be submitted in connection with the Project shall be
borne by the Developers pro rata to their Cost-Sharing Percentages. The Developers agree that if
any payment is made under any bid bond, development bond or guarantee, or if any Developer or any
Affiliate of a Developer makes any payment under or in connection with any such bid bond,
development bond or guarantee, in each case with respect to the obligations of the Developers and
their Affiliates regarding the Project, then such payment shall be considered an External
Development Cost, and each other Developer shall reimburse to the Developer or Affiliate making the
payment, on demand, its Cost-Sharing Percentage of the payment, plus interest at the Specified Rate
from the date the payment was made until the reimbursement is made.

B-11

 

ARTICLE IV

PROJECT ENTITY

     4.01 Generally. The Developers intend that the Project will be constructed, financed, owned,
and operated through one or more special-purpose companies, partnerships, or other entities or
associations (each, a “Project Company”).

     4.02 Features. The Project Company will have the following features, along with such other
features as the Developers may agree:

     (a) Subject to any third party rights, the initial Equity Owners will be Affiliates of
the Developers, and will be obligated to make contributions to the Project Company
(including without limitation pursuant to the Equity Subscription Agreement and the
Development Budget) and be entitled to receive distributions in the following percentages:

	 	 	 	 	 
	 

	 	Lead Developer
	 	                    %
	 

	 	                                        
	 	                    %
	 

	 	                                        
	 	                    %

          Each Developer shall also bear Development Costs in proportion to the percentages listed above
(the “Cost-Sharing Percentages”).

     (b) The Project Company will be formed under the laws of the jurisdiction determined by
the Lead Developer, taking into account the tax impacts or benefits to each Developer and
Equity Owner of such choice.

     (c) The Project Company’s sole purpose shall be conducting activities relating to the
Project.

     (d) An Equity Owner may transfer its interest in the Project Company only (i) to an
Affiliate of the Equity Owner; or (ii) with the prior consent of a majority-in-interest of
the other Equity Owners, to a party that is not its Affiliate. If required under the
Financing Agreements, and if any Developer is not otherwise precluded from doing so due to
some other contractual or legal obligation, each Equity Owner will pledge its interests in
the Project Company to the Lenders or their representatives.

     4.03 Board of Directors. [TO BE AGREED FOR EACH PROJECT] (a) [If the Equity Owners
are owned in their entirety by AEI and SES or their Affiliates (i.e., no third party owns any
interest in the Project Company), then AEI and SES shall have representation on the board of
directors of the Project Company in proportion to the ownership interest held by each of AEI and
SES.]

     (b) If any third party Equity Owner owns any interest in the Project Company, then AEI
and SES shall form a holding company which will own the combined interest of

B-12

 

AEI and SES in the Project Company. AEI and SES shall have representation on the board
of directors of such Holding Company in proportion to the ownership interest held by each of
AEI and SES in such Holding Company.]

     4.04 Supermajority Vote Requirements. The following items will require supermajority vote of
at least seventy percent (70%) of the board of directors for the Project Company:

     (a) material dispositions or acquisitions;

     (b) entering into or amending, modifying, waiving any right or initiating any dispute
resolution provision under any Project Contract;

     (c) the approval of all construction budgets for the Project or material change orders;

     (d) the issuances of new equity or other material changes to capital structure;

     (e) the amendment of the organizational documents or Shareholders Agreement of the
Project Company;

     (f) the incurrence by the Project Company of debt in excess of fifty percent (50%) of
the Project Company’s assets; and

     (g) any transaction between (i) the Project Company and (ii) any Developer or an
Affiliate of any Developer.

     4.05 Simple Majority Vote Requirements. All items to be voted upon by the board of directors
of the Project Company that are not listed in Section 4.04 shall require a simple majority vote.

     4.06 Tie-Breaking Vote (Operating Budgets). With respect to any matter involving the
operating budget of the Project, to be determined by a simple majority vote, AEI’s vote shall be
used to break any tie in the voting of the board of directors.

     4.07 Appointment of Management.

     (a) AEI shall appoint the management of the Project Company, including, a General
Manager (Chief Executive Officer) and either a Controller or a Chief Financial Officer.

     (b) SES shall have the right to appoint the Deputy General Manager (Chief Operating
Officer) and the Operations Manager – Gasification Island for the Project Company.

     4.08 Policies and Procedures. The Project Company shall adopt corporate policies and
procedures proposed by AEI, which policies and procedures shall include, without limitation: (a)
policies related to the FCPA; (b) Code of Conduct; and (c) Finance, Treasury and

B-13

 

Accounting, which shall comply with the minimum requirements of SES imposed upon it as a
public company. AEI shall consider suggestions from SES regarding the same, to the extent that
they do not conflict in a negative way with AEI’s required policies and procedures.

ARTICLE V

PROJECT CONTRACTS AND FINANCING AGREEMENTS

     5.01 Project Contracts. (a) The Project Company will enter into the Project Contracts, which
may be with Affiliates of Developers. The Developers shall endeavor to have the Project Contracts
include provisions for payment in Dollars [outside the Project Country] and to obtain appropriate
Authorizations to allow payment in this manner, if required.

     (b) The Project Company may enter into a Project Contract with a Developer’s Affiliate
only if the terms are arm’s-length and competitive with those that have been or would be
offered to or by third parties. Once a Project Contract has been approved as provided in
Section 2.04, however, it shall be deemed to have met the requirements of this Section
5.01(b).

     5.02 Financing Agreements. (a) The Developers intend to arrange for financing of the costs
of developing, constructing, and equipping the Project on a limited-recourse, project-financed
basis through one or more international financing sources. The Project Company may refinance prior
financings one or more times.

     (b) If required in connection with any such financing, the Project Company shall assign
its rights under Project Contracts to the Lenders, but the Lenders shall be liable for the
Project Company’s obligations only to the extent they acquire the Project Company’s interest
in connection with or in lieu of foreclosure.

     (c) Each Developer whose Affiliate is a party to a Project Contract shall cause that
Affiliate to execute and deliver customary consents, acknowledgments, pledges of interests
in the entities, and opinions in connection with any such financing and provide all
financial and credit information about that Affiliate that is customary for financings of
this nature.

     5.03 Approval. Each agreement to be entered into as provided in this Article V must be
approved in accordance with Section 2.04, whereupon the Developers shall cause the Project Company
to approve it in accordance with Sections 4.04 and 4.05, as applicable. Nonetheless, each
Co-Developer agrees to approve, and to cause any of its Affiliates that is an Equity Owner to
approve or vote to approve, any agreement to be entered into as provided in this Article V
recommended by the Lead Developer (other than a Project Contract to which an Affiliate of the Lead
Developer is a party) if the terms of that agreement are customary for projects similar to the
Project to be financed through international debt and equity markets on a limited-recourse basis
and meet any other applicable requirements of this Agreement, including the selection of a
recognized and widely acceptable governing law and provisions similar to those in ARTICLE VIII and
Section 12.02.

B-14

 

ARTICLE VI

TRANSFER AND WITHDRAWAL

     6.01 General. (a) A Developer may withdraw from development of the Project at any time prior
to the Final Investment Decision upon written notice to each other Developer, subject to executing
any documents and obtaining any consent required to effect the transfer contemplated by Section
6.02. A Developer’s withdrawal from the Project shall become effective on the date such written
notice is delivered to each other Developer (the “Termination Date”). A withdrawing
Developer shall have no further obligations any other Developer with respect to the Project, except
for (a) its share of costs incurred, accrued, or otherwise contractually committed to the Project
as of the Termination Date, (b) the survival of its confidentiality obligations pursuant to Section
7.04, and (c) any other obligations set forth in this ARTICLE VI. Effective on the Termination
Date, a withdrawing Developer shall (i) have no residual interest or claim to the Project; and (ii)
release and transfer its equity interest in the Project Company. As soon as reasonably practicable
after such withdrawal, the Developers shall execute and deliver a Termination and Release
Agreement, substantially in the form of Exhibit “F,” to terminate this Agreement with respect to
such withdrawing Developer, and shall execute and deliver such further consents, agreements, and
other documentation as may be required to effect the withdrawal of the applicable Developer.

     (b) Any Developer that fails to make any mandatory funding obligations or otherwise
fails to comply with any capital contribution obligation under any Project Contract shall be
deemed to have withdrawn from such Project as of the date of such failure to make such
funding obligation or capital contribution and the procedures set forth in Section 6.02
shall apply.

     6.02 Terms of Transfer on Withdrawal. The transfer of the interests of a withdrawing
Developer and its Affiliates under Section 6.01 shall be made on the following terms:

     (a) The transfer shall include all the former Developer’s and its Affiliates’ rights,
titles, and interests in and to this Agreement and the Project, including its interests (if
any) in the Project Company, Authorizations, Project Contracts and all other contracts with
third parties (to the extent it is a representative of the Project or the Project Company,
but not in its or its Affiliates’ individual capacities), drawings, diagrams, plans, or
other intellectual property, and drawings and engineering work in the possession of the
former Developer and its Affiliate(s) paid for through the reimbursement of Development
Costs.

     (i) The transfer shall be made without representation, warranty, covenant, or indemnity
of any kind, other than that the interests so sold are transferred free and clear of any
lien, security interest, or adverse claim, other than those specifically created under the
Financing Agreements and the organizational documents of the Project Company or the
Shareholders Agreements or similar documents.

     (ii) The withdrawing Developer shall cease to be a Developer and to have any rights
under this Agreement or with respect to the Project or any liability to any

B-15

 

other Developers under this Agreement (except as may be otherwise provided in the
documentation with respect to such transaction), and its Cost-Sharing Percentage and right
to acquire interests in the Project Company shall be vested in the remaining Developers;
provided, however, that:

     (A) the withdrawing Developer shall retain all rights to receive
reimbursement of Development Costs incurred by such Developer, in accordance
with this Agreement;

     (B) the withdrawing Developer and its Affiliates shall continue to be
bound by the provisions of Sections 7.04, 7.05, 7.07 and 7.08;

     (C) the provisions of Articles VIII (Resolution of Disputes), X (Force
Majeure) and XII (Miscellaneous) shall continue in effect to the extent
applicable with respect to the withdrawing Developer and its Affiliates; and

     (D) All Project Contracts, Financing Agreements and Equity Subscription
Agreements to which the withdrawing Developer or its Affiliates are parties
in their individual capacities (as opposed to representatives of the Project
or the Project Company), if any, shall continue in full force and effect.

ARTICLE VII

ADDITIONAL OBLIGATIONS

     7.01 Technology License. As the licensor of the U-Gas Technology, SES shall grant and confirm
to the Project Company, as applicable, an exclusive, non-transferable license and right to use the
U-Gas Technology for coal conversion in connection with the Project. In consideration of the
license granted herein, SES shall be compensated as follows:

     (a) AEI agrees to pay to SES, for the Project, an upfront royalty of $10 for each
Thermal MegaWatt/hr (MWt) of dry syngas production of rated design capacity of the Project.

     (i) The royalty shall be paid in two equal installments: the first installment
shall be paid upon the execution of the EPC Contract for the construction of the
Project; and the last installment shall be paid upon the completion of the
construction of the unit that uses the U-Gas Technology.

     (ii) If the Project consists of more than one unit that uses the U-Gas
Technology, and such units shall be built over a period of years, then the second
installment of the royalty shall be paid proportionately at the completion of each
unit.

     (b) SES shall be entitled to an energy royalty fee calculated as follows:

B-16

 

     _________.

     7.02 Equipment Supply and Support. SES provide Equipment, support and services to the
Project, pursuant to an Equipment Supply Agreement, which if entered into between the Project
Company and SES, will have the general terms and conditions set forth on Exhibit E.

     7.03 Observance of Laws. (a) With respect to all matters and activities relating to the
Project and the Project Company, each Developer shall comply with, and shall cause its Affiliates
that are involved in the Project to comply with, all laws, rules, or regulations of the Project
Country and any other jurisdiction that are applicable to such Developer or its Affiliates’
activities in connection with the Project, including in particular the FCPA. Each Developer
covenants and agrees that the representations and warranties in Section 9.02 (other than as
pertains to ownership) shall continue to apply to the parties following the date of this Agreement,
and each Developer covenants and agrees that it shall not and its representatives shall not take
any action or omit to take any action that would cause such party to not be in full compliance with
all such representations and warranties at all times after the date of this Agreement.
Furthermore, each Developer agrees that it and its Affiliates will not take any action or fail to
take any action, which act or failure to act would subject any other Developer or any of its
Affiliates to liability under the laws of its country of domicile.

     (b) Each Developer shall notify each other Developer in writing promptly upon (i) the
discovery of any noncompliance with the said representations and warranties, whether such
noncompliance occurred before or after the date hereof, (ii) the occurrence of any change in
circumstances on a date after the date hereof which renders the said representations and
warranties incorrect or misleading as of such subsequent date, and (iii) any change in its
direct or indirect shareholders or other equity owners.

     (c) Each Developer agrees that it or its Affiliates will obtain the agreement of each
consultant or contractor it or, if applicable, its Affiliates employs in conducting
activities for, related to or on behalf of the Project to comply with the FCPA, and if the
employment cost exceeds $100,000 in the aggregate, shall obtain written agreement to that
effect.

     (d) Each Developer shall provide a certification to the effect that it has not, and its
Affiliates have not, made any payments, directly or indirectly, in violation of this
Section: (i) to each other Developer, within thirty (30) days after the end of each fiscal
year; and (ii) to a requesting Developer on or before the 60th day after notice from another
Developer so requesting. Each Developer warrants and represents to each other Developer
that prior to the execution of this Agreement it and its Affiliates have not taken any
action, or failed to take any action, with respect to the Project that would have violated
this Section had this Section then been in effect.

     7.04 Confidentiality. Except as hereinafter provided, the provisions of this Agreement, the
Joint Development Agreement and all information or documents which come into the possession of the
Developers in connection with the performance hereof or thereof, including any and all data,
information, plans, proposals, contracts, or other materials related to the design, construction,
configuration, financing, or operation of the Project which are delivered or

B-17

 

disclosed by a Developer to each other Developer under this Agreement, or developed and paid
for by the Project Company or jointly by the Developers (the “Confidential Information”),
may not be used or communicated to third parties without mutual written agreement of each other
Developer. However, any Developer shall have the right to disclose such provisions, information or
document without any other Developer’s consent:

     (a) to legal counsel, accountants, financial advisers, lenders, other professional
consultants, and insurance underwriters for a Developer or any of its Affiliates, provided
such disclosure is solely to assist such Person in performing the functions for which they
were engaged in connection with the Project, and for recipients other than legal counsel,
the recipient undertakes to keep such information or documents under terms of
confidentiality equivalent to this Section 7.04;

     (b) if required by any court of law or any law, rule, or regulation having jurisdiction
over a Developer, or if requested or required by an agency of any government having or
asserting jurisdiction over a Developer, any guarantor of such Developer’s obligations
hereunder, or any of their respective Affiliates and having or asserting authority to
require such disclosure in accordance with that authority or pursuant to the rules of any
recognized stock exchange or agency established in connection therewith, provided, that a
Developer making such a required disclosure shall make good faith efforts to advise each
other Developer of the same as soon as reasonably practicable, and shall make reasonable
efforts to secure protective treatment for the disclosed information and with respect to any
disclosure requirements of any recognized stock exchange, shall cooperate with the
non-disclosing Developer regarding the information to be disclosed;

     (c) to any Affiliate of a Developer; provided the recipient undertakes to keep such
information or documents under terms of confidentiality equivalent to this Section 7.04;

     (d) to the extent any such information or document has (i) been independently developed
by the recipient, (ii) has been acquired from a third party, or (iii) entered the public
domain other than through the fault or negligence of the Developer making the disclosure
(for this purpose any disclosure by a permitted recipient of a Developer (as aforesaid)
shall be deemed to be the fault or negligence of such Developer);

     (e) to an arbitration tribunal in connection with resolution of a Dispute under this
Agreement; and

     (f) to the extent permitted under Section 7.07.

     7.05 Use of Confidential Information. Upon termination of the confidentiality period
described in Section 7.06, each Developer shall be entitled to utilize Confidential Information;
provided, however, such utilization shall not include selling, trading or publishing to a third
party such Confidential Information.

     7.06 Survival. The terms of Section 7.04 shall survive the termination of this Agreement and
remain in effect for a period of three (3) years after such termination; provided, however, that
any confidentiality obligations owed by the Developers to any third-party shall

B-18

 

survive for such longer period, if any, as may be specified in the agreement creating such
confidentiality obligation. It is understood that Section 7.04 shall not prohibit, prevent, or
hinder the use of Confidential Information in the development of the Project under this Agreement.

     7.07 Publicity. No Developer may make or issue any press release, public announcement, or
statement regarding this Agreement, the Joint Development Agreement or the Project without the
consent of each other Developer, which consent shall not be unreasonably withheld. However, no
such consent shall be required if a Developer is required to issue or make any press release,
public announcement, or statement by applicable law or judicial proceeding, or by governmental
order, decree, regulation or rule, or by the listing requirements of the stock exchange on which a
Developer or any of its Affiliates is listed; provided, however, that a Developer making such a
required disclosure shall make good faith efforts to advise each other Developer of the same as
soon as reasonably practicable. The Developers shall cooperate to establish a public affairs
program to pre-approve announcements, answer questions, and draft statements that may be used by
the Developers in connection with the Project. Notwithstanding any provision herein to the
contrary, no party shall have the right to make reference to, or otherwise use the name of the
other party without the prior written consent of such party.

     7.08 Exclusivity and Competition. A Developer may not, and will cause its Affiliates not to,
negotiate with any Person (other than the Developers and their Affiliates or the Project Company as
contemplated by this Agreement) or enter into any agreement or understanding with any other Person
regarding the Project. Each Developer understands that each other Developer and its Affiliates are
incurring substantial Development Costs in reliance on their rights under this Agreement and that
this exclusivity is essential for the integrity and viability of the Project and its development.
Notwithstanding this Section 7.08, the Developers recognize that it may be beneficial to involve
third parties in certain aspects of the development or ownership of the Project on terms to be
agreed by the Developers.

     7.09 Information. Each Developer shall furnish to each other Developer such information
concerning the development of the Project in such detail and with such frequency as that Developer
reasonably may require, including information required for a Developer or its Affiliates to prepare
their tax returns on a timely basis.

ARTICLE VIII

RESOLUTION OF DISPUTES

     8.01 Exclusive Procedures and Negotiation in Good Faith. (a) Any dispute, claim, or
controversy arising out of or relating to the Project, this Agreement, or the performance, breach,
validity, application, or termination thereof, (“Dispute”) shall be resolved in accordance
with the procedures specified in this Article VIII, which shall be the sole and exclusive
procedures for the resolution of any such Disputes.

     (b) In the event of any Dispute, the Developers shall first attempt in good faith to
resolve such Dispute promptly by negotiation between representatives of the Developers who
have authority to settle the Dispute. Any Developer may give each other Developer written
notice of any Dispute not resolved in the normal course of business. Within 10

B-19

 

business days after delivery of that notice, the receiving Developer shall submit to
the other a written response. Within thirty (30) business days after delivery of the notice
of Dispute, the representatives of the Developers shall meet at a mutually acceptable time
and place, and thereafter as often as they reasonably deem necessary, to attempt to resolve
the Dispute. If a Developer refuses to negotiate as provided herein or if the Dispute has
not been settled within 60 days of the delivery of the notice, any Developer may immediately
initiate arbitration as provided in Section 8.02.

     8.02 Agreement to Arbitrate. Any Dispute not resolved by negotiation as provided above shall
be finally resolved by binding arbitration under the Rules of Arbitration (“Rules”) of the
International Chamber of Commerce (“ICC”) by arbitrators appointed in accordance with the
said Rules and this Agreement.

     8.03 Number and Appointment of Arbitrators. The arbitral tribunal shall be composed of three
neutral, independent, and impartial arbitrators (the “Tribunal”). In the request for
arbitration, the Developer requesting arbitration (the “Claimant”) shall nominate one
arbitrator. The other Developers (collectively, the “Respondents”) shall nominate one
arbitrator within the time specified in the Rules. The two arbitrators nominated by the Claimant
and Respondents shall together nominate the third arbitrator, who shall be the chairman of the
Tribunal, by mutual agreement within twenty (20) days of their appointment of the second
arbitrator. If any nominated arbitrator is not appointed, declines, resigns, becomes
incapacitated, or otherwise refuses or fails to serve or to continue to serve as an arbitrator, the
party or arbitrators entitled to nominate that arbitrator shall promptly nominate a successor.
Should a party fail to nominate an arbitrator, or should the two party appointed arbitrators fail
to nominate a chairman, the ICC shall make the appointment.

     8.04 Venue; Procedural Issues. The seat of the arbitration shall be Houston, Texas. The
arbitration shall be conducted and the award rendered solely in the English language. The
Developers agree that in matters of disclosure and evidence in the arbitration, the Tribunal shall
be guided by the Rules On the Taking of Evidence in International Commercial Arbitration of the
International Bar Association. Subject to any relevant legal privilege against disclosure, the
Tribunal shall have the power to make all appropriate orders necessary for disclosure, which orders
the Developers consent in advance to obey.

     8.05 Powers of the Arbitrators; Limitations On Remedies. The validity, construction, and
interpretation of this agreement to arbitrate, and all procedural aspects of the arbitration
conducted pursuant to this agreement to arbitrate, shall be decided by the Tribunal. The Tribunal
shall have the power to award all remedies available under the applicable law except that the
Tribunal shall have no power to award any consequential, punitive, or special damages and shall
have no power to rely on the applicable law to avoid this limitation, regardless of whether such
excluded remedies would be available under the applicable law. The Tribunal shall not decide the
Dispute by reliance on any other doctrine or principle that would permit the Tribunal to avoid the
application of this Agreement and/or the applicable law. The Tribunal shall also have the power to
enter such interim orders as it deems necessary, including, without limitation, orders to preserve
the subject matter of the Dispute or to preserve or adjust the status of the parties pending
resolution of the Dispute in arbitration.

B-20

 

     8.06 Arbitration Awards. The Tribunal shall expedite all procedures and take all reasonable
efforts to expedite an award. The award shall be in writing, shall give reasons for the decisions
reached by the Tribunal. A copy of the award shall be contemporaneously delivered to each of the
Developers. The Developer against which an award assesses a monetary obligation or enters an
injunctive or mandatory order shall pay that obligation or comply with that order on or before the
thirtieth (30th) day following the receipt of the final, signed award or by such other
date as the award may provide. The award shall be final and binding on the Developers and may be
confirmed in, and judgment upon the award entered by, any court having jurisdiction over the
Developers. The Tribunal’s award shall be entitled to all of the protections and benefits of a
final judgment as to any Dispute, shall be final and binding on the Developers and non-appealable
to the maximum extent permitted by law, and each Developer shall be estopped from raising any
claims that such Developer could have presented to the Tribunal during the arbitration. Each
Developer affirmatively waives, to the maximum extent permitted by applicable law, any right to
contest the recognition or enforcement of the award in any jurisdiction where recognition or
enforcement may be sought on the award.

     8.07 Confidentiality. Except to the extent necessary for proceedings relating to enforcement
of the arbitration agreement, the award or other, related rights of the parties, the fact of the
arbitration, the arbitration proceeding itself, all evidence, memorials or other documents
exchanged or used in the arbitration and the arbitrators’ award shall be maintained in confidence
by the Developers to the fullest extent permitted by applicable law. However, a violation of this
covenant shall not affect the enforceability of this agreement to arbitrate or of the Tribunal’s
award.

     8.08 Costs of Arbitration. The Tribunal shall designate a prevailing Developer in its final
award. Pursuant to this determination, the Tribunal shall award to the prevailing Developer its
attorneys’ fees, costs and expenses of the arbitration (including the arbitrators’ fees and
expenses) as they deem appropriate.

     8.09 Interest. The award shall include interest, which shall run from the date of any breach
or violation of this Agreement, which shall be determined by the Tribunal in its award. Interest
shall continue to run from the date of award until the award is paid in full. Interest shall be
calculated and compounded monthly at the Specified Rate.

     8.10 Pre-arbitral Referee. Any Developer shall have the right to have recourse to the
Pre-Arbitral Referee Procedure of the ICC in accordance with its Rules for a Pre-Arbitral Referee
Procedure; provided, however, that (a) the answer to the request for a Pre-Arbitral Referee (the
“Referee”) must be submitted no later than the seventh (7th) day following
receipt of such request for such Referee, (b) the Referee shall be appointed by the ICC, if
possible within seven (7) business days of the request for such Referee, and (c) the Referee shall
issue his order within ten (10) days of the later of receipt of the answer or his appointment
unless exceptional circumstances require additional time, in which case the Order must be issued
within twenty (20) days of the above dates. The Pre-Arbitral Referee Procedure is without
prejudice to the agreement to arbitrate contained in this Article VIII.

     8.11 No Immunity. To the extent that any Developer may in any jurisdiction claim for itself,
or its assets or revenue, immunity from suit, execution, attachment, or other legal process

B-21

 

with respect to this Agreement, or the performance, nonperformance or breach thereof, and to
the extent that in any such jurisdiction there may be attributed to a Developer, or its assets or
revenues, such immunity (whether or not claimed), each Developer agrees not to claim and hereby
irrevocably waives such immunity to the full extent permitted by the laws of such jurisdiction.

ARTICLE IX

REPRESENTATIONS, WARRANTIES, INDEMNITIES AND LIABILITIES

     9.01 Representations. Each Developer hereby (a) represents and warrants to each other
Developer the following as of the date hereof and (b) covenants to each other Developer that at all
times thereafter during the Term of this Agreement, that it will cause the following
representations and warranties to be true and correct in all material respects, except that, to the
extent that any such representation and warranty is qualified by materiality, such representation
or warranty shall be true and correct in all respects:

     (a) It is a duly organized, validly existing entity of the type described in the
preamble to this Agreement and (if applicable) is in good standing under the laws of the
jurisdiction of its formation and is duly qualified to do business and (if applicable) in
good standing as a foreign corporation in the jurisdiction of its principal place of
business (if not formed in that jurisdiction). It has all requisite power and authority to
enter into and to perform its obligations under this Agreement and has obtained (to the
extent applicable law permits the obtaining of same at this point in time) all approvals
from applicable governmental authorities necessary for it to enter into and to perform its
obligations under this Agreement.

     (b) Its execution, delivery, and performance of this Agreement have been duly
authorized by all necessary action on its part and that of its equity owners, and do not and
will not (i) violate any law, rule, regulation, order, or decree applicable to it or (ii)
violate its organizational documents.

     (c) This Agreement is a legal and binding obligation of that Developer, enforceable
against that Developer in accordance with its terms, except to the extent enforceability is
modified by Bankruptcy, reorganization and other similar laws affecting the rights of
creditors generally and by general principles of equity.

     (d) There is no litigation pending or, to the best of its knowledge, threatened to
which that Developer or any of its Affiliates is a party that could reasonably be expected
to have a material adverse effect on the financial condition, prospects, or business of that
Developer or its ability to perform its obligations under this Agreement.

     (e) The execution, delivery and performance of this Agreement will not conflict with,
violate or breach the terms of any agreement of that Developer or of any agreement to which
its properties are subject.

     (f) It is not, and shall not become, a person or entity with whom any other Developer
is restricted from doing business with under the regulations of the Office of

B-22

 

Foreign Asset Control (“OFAC”) of the Department of the Treasury (including,
but not limited to, those named on OFAC’s Specially Designated and Blocked Persons list) or
under any statute, executive order (including, but not limited to, the September 24, 2001,
Executive Order Blocking Property and Prohibiting Transactions With Persons Who Commit,
Threaten to Commit, or Support Terrorism), or other action of any governmental authority.

     (g) It will not attempt to assign, transfer, enter into a disposition of an equity
interest or any rights or obligations under this Agreement, or attempt to develop a project
that is similar to the Project with respect to any third party identified in the U.S.
Department of Treasury’s Excluded Parties Lists System at http://www.epls.gov/.

     9.02 Compliance with Law. Each Developer, with respect to itself and its Affiliates, hereby
(a) represents and warrants the following to each other Developer as of the date hereof and (b)
covenants to each other Developer that at all times thereafter during the Term that it will cause
the following representations and warranties to be true and correct, except that, to the extent
that any such representation and warranty is qualified by materiality, such representation or
warranty shall be true and correct in all respects:

     (a) It has conducted its affairs and activities in respect of this Agreement in
accordance with applicable laws in all material respects.

     (b) It has not, and covenants and agrees that its employees, agents, consultants,
advisors, representatives will not, in connection with the purpose or any transactions
contemplated by this Agreement, make, promise or offer to make any payment or transfer of
anything of value, directly or indirectly: (i) to any Government Official or to an
intermediary for payment to any Government Official; or (ii) to any political party. Each
Developer further covenants and agrees that neither it nor any of its representatives will
make, in connection with the purpose or any transactions contemplated by this Agreement, any
payments or transfers of anything of value, directly or indirectly, for the purpose or
effect of public of commercial bribery, acceptance of or acquiescence in extortion,
kickbacks or other unlawful or improper means of obtaining or retaining business or securing
any improper advantage. This Section 9.02(b) shall not, however, prohibit normal and
customary business mementos of nominal value in connection with the Developers’ performance
under this Agreement.

     (c) No ownership or profit sharing interest, direct or indirect, in the Developer, or
in the contractual relationship established by this Agreement, is held or controlled by or
for the benefit of any Government Official (except to the extent that such Government
Official acquired such interest independently, from an open securities market), and that the
Developer will immediately notify each other Developer in the event of a change in the
foregoing; and it has not taken any action that would subject any Developer or the Project
Company to liability or penalty under any applicable law, rules, regulations or decrees of
any Governmental Authority.

     (d) Each Developer agrees that should it learn or have reason to know of: (a) any
payment, offer, or agreement to make a payment to a Government Official or

B-23

 

political party for the purpose of obtaining or retaining business or securing any
improper advantage for the Developer in connection with this Agreement or otherwise, or (b)
any other development during the term of the Agreement that in any way makes inaccurate or
incomplete the representations, warranties and certifications of the Developers set forth in
this Section 9.02, it will immediately advise the other in writing.

     (e) In order to verify compliance with the provisions of this Agreement and/or any
other agreement signed between the Developers, the Developers agree that each Developer
shall have the right, from time to time, upon written notice to each other Developer, to
audit the books and records of the other to the extent such books and records relate to the
performance of this Agreement and any payments made under this Agreement. Each Developer
agrees to furnish promptly to each other Developer any additional information that may
reasonably be requested to verify compliance with the provisions herein.

     (f) The Developers agree that full disclosure of information relating to this
Agreement, including the compensation provisions, may be made at any time and for any reason
to the U.S. government and the respective jurisdictions of the operating businesses, its
agencies, and to any other person, to any Developer, as applicable; provided that the
Developer disclosing such information shall, to the extent permitted by applicable law,
notify each other Developer of such disclosure and the information disclosed.

     9.03 Intellectual Property. SES hereby (a) represents and warrants the following to AEI, as
of the date hereof and (b) covenants to AEI that at all times thereafter during the Term that it
will cause the following representations and warranties to be true and correct, except that, to the
extent that any such representation and warranty is qualified by materiality, such representation
or warranty shall be true and correct in all respects: (a) it is not aware of any prior art which
would invalidate any claims of any patents owned by SES or any of its Affiliates related to the
U-Gas Technology, (b) it is not aware of any third party’s patent or patents which have been or
would be infringed by the use or sale of the U-Gas Technology, (c) neither SES nor any of its
Affiliates have received any assertions from others that the claims of any patents owned by SES or
any of its Affiliates are invalid or unenforceable or that the U-Gas Technology infringes any
patents, copyrights, trade secret rights or other intellectual property rights of others, (d) it is
not aware of any actions or inactions which would render unenforceable any claims of any patents
related to U-Gas Technology owned by SES or any of its Affiliates, (e) pursuant to that certain
Amended and Restated License Agreement by and among SES and GTI dated August 31, 2006, SES has an
exclusive license to manufacture, make, use and sell U-GAS Technology worldwide, and (f) neither
the entry into this Agreement nor the granting of a license or sub-license by SES to AEI, any of
AEI’s Affiliates, any Holding Company or the Project Company requires the consent or approval of
any third party, including but not limited to GTI.

     9.04 Indemnification and Limitation on Liability.

     (a) Except as provided herein, no Developer or its respective shareholders, directors,
officers, employees, and agents shall have any liability to any other Developer for any loss
suffered by any other Developer arising out of any action or omission by any

B-24

 

of them, so long as such action or omission (i) was in good faith; (ii) was consistent
with the provisions of this Agreement; and (iii) did not constitute the gross negligence or
willful misconduct of the Developer involved.

     (b) Each of AEI and SES agree severally (not jointly) to defend, indemnify, and hold
harmless each other Developer, the Project Company and their respective Affiliates and their
respective shareholders, directors, officers, employees and agents (collectively,
“Indemnitees”) from and against any losses, damages, judgments, liabilities,
expenses, and amounts paid in settlement of any claims with respect to death, personal
injury, or damage to property of a third party due to the gross negligence or willful
misconduct of such indemnifying Developer, its Affiliates and their respective shareholders,
directors, officers, employees and agents.

     (c) Each of AEI and SES agree severally (not jointly) to defend, indemnify and hold
harmless each other Developer and its respective Indemnitees from all losses, damages,
judgments, liabilities, expenses, and amounts paid in settlement, that relate to, result
from, or are in connection with, any misrepresentation or breach of any warranty or
representation given by such Developer in this Agreement or the Joint Development Agreement,
or breach of any covenant or agreement made by such Developer in this Agreement or the Joint
Development Agreement.

     (d) In no event, whether as a result of breach of this Agreement or any resulting
contract therefrom, warranty, indemnity, tort (including negligence), strict liability or
otherwise, shall any Developer be liable to any other Developer for any consequential
damages, special or incidental damages, lost profits, punitive damages, exemplary damages,
enhanced damages, multiple damages, indirect damages, or other penalty or speculative
damages arising out of this Agreement or the Joint Development Agreement.

     (e) SES shall defend, indemnify and hold harmless the Project Company, AEI and its
respective Indemnitees from and against any and all claims of infringement or
misappropriation of patent, copyright, trademark, trade secret rights, confidential
information, proprietary rights or other intellectual property rights based upon the use or
sale, in accordance with this Agreement and the Joint Development Agreement, of the U-Gas
Technology by AEI or the Project Company, with respect to the Project.

     (f) A Developer shall notify each other Developer in writing promptly after it becomes
aware of any facts that may lead to the making of a claim for indemnification under this
Agreement. Any amounts owing by a Developer under this Section 9.04 shall be due and
payable within ten (10) days of the final resolution of the underlying claim pursuant to
this Agreement.

     (g) The provisions of this Section 9.04 shall survive the termination of this Agreement
or the withdrawal of any Developer from the Project.

     9.05 No Fiduciary Duty. In their relations with each other under this Agreement, the
Developers shall not be considered fiduciaries, and each Developer agrees not to assert any claim

B-25

 

that the Developers are fiduciaries. Without in any way limiting the foregoing, each
Developer may grant or withhold its consent, approval or vote, in its sole discretion, without
regard to the interests of or any obligation to any other Developer or its subsidiaries, it being
understood that no Developer has any fiduciary or other express or implied duty to represent or act
in the best interests of such other Developer. The provisions of this Section 9.05 shall survive
the termination of this Agreement or the withdrawal of any Developer from the Project.

     9.06 Non-Recourse. The obligations of the Developers under this Agreement are obligations of
the Developers only, and no recourse shall be available against any officer, director, or equity
holder.

ARTICLE X

FORCE MAJEURE

     10.01 General. A Developer’s obligations under this Agreement shall be excused when and to
the extent its performance of those obligations is prevented due to Force Majeure; provided,
however, that a Developer shall not be excused by Force Majeure from any obligation to pay money.
The Developer rendered unable to fulfill its obligations under this Agreement by reason of Force
Majeure shall notify each other Developer of this circumstance and shall exercise due diligence to
end the inability as promptly as practicable; provided, however, that a Developer is not required
to settle any strike or labor dispute in which it may be involved.

     10.02 Definition. “Force Majeure” means any cause beyond the reasonable control of the
Developer failing to perform, including causes such as:

     (a) flood, earthquake, storm, dust storm, lightning, fire, perils of sea, epidemic,
explosion, pestilence, holocaust, act of God, or failure or breakdown of facilities and/or
Equipment from any other cause not specifically listed in this subsection (a) or in
subsection (b), provided failure or breakdown of the facilities and/or Equipment is not
caused by the failure by the Developer claiming Force Majeure to operate and maintain those
facilities and/or Equipment in accordance with this Agreement or good engineering and
operation practices; or

     (b) war (regardless of whether declared), act of public enemy, act of civil or military
authority, civil disturbance or disobedience, riot, religious strife, sabotage, terrorism,
threats of sabotage or terrorism, restraint by court order or order of public authority,
action or non-action by or inability to obtain the necessary Authorizations or other
authorizations or approvals from any government, political subdivision, agency,
instrumentality, expropriation, requisition, confiscation, export or import restrictions,
closing of ports, airports, terminals, roadways, waterways, or rail lines, rationing or
allocation scheme (whether imposed by Governmental Authorities or by industry in cooperation
with Governmental Authorities), or labor or material shortage.

ARTICLE XI

DEFAULT AND TERMINATION

B-26

 

     11.01 Event of Default. A Developer shall be in default hereunder if, at any point during the
Term of this Agreement, it is in breach of any of the representations, warranties or covenants made
by such Developer in accordance with Article IX. If a Developer becomes aware of a default
hereunder by any other Developer, it shall notify each other Developer in writing of such default.
Each non-defaulting Developer shall have the right to terminate this Agreement if the defaulting
Developer fails to remedy it default hereunder within forty-five (45) days of receipt of the
written notice of default provided by the non-defaulting Developer.

     11.02 Additional Events of Default. In addition to any other termination rights provided in
this Agreement, the circumstances set forth below shall give rise to the right for any Developer to
terminate this Agreement. Each non-defaulting Developer shall have the right to terminate this
Agreement if the defaulting Developer fails to remedy its default hereunder within forty five (45)
days of receipt of the written notice of default provided by a non-defaulting Developer in
accordance with this Section 11.02.

     (a) The Bankruptcy of any other Developer. For purposes of this Section 11.02(a),
“Bankruptcy” shall mean, with respect to any Developer, (i) such Developer’s
suspension of payment of, or request from any court of a moratorium on payment of, all or a
substantial part of such Developer’s debts, (ii) such Developer’s making of a general
assignment or any composition with or for the benefit of its creditors, (iii) any filing or
consent by answer or otherwise by such Developer to the filing against it of a petition for
relief or reorganization or arrangement or any other petition in bankruptcy, for liquidation
or to take advantage of any bankruptcy, insolvency, reorganization, moratorium or other
similar law of any jurisdiction, or (iv) any order: (w) entered for the winding up,
bankruptcy, liquidation, dissolution, custodianship or administration with respect to such
Person or any substantial part of such Developer’s property, or (x) constituting an order
for relief, or (y) approving a petition for relief or reorganization or any other petition
in bankruptcy or insolvency law of any jurisdiction, or (z) approving any petition filed in
bankruptcy or insolvency law of any jurisdiction against such Developer;

     (b) The failure by any Developer to pay an amount not in dispute in excess of
$500,000.00;

     (c) The occurrence of any change, circumstance or event that would materially hinder a
Developer’s ability to consummate the transactions contemplated by this Agreement or the
Joint Development Agreement;

     (d) Any Developer or any Affiliate of any Developer is in breach of any representation
or warranty, or otherwise in material breach under the Joint Development Agreement (subject
to any cure right set forth in such agreement);

     (e) In the event any Developer is found, through a final determination made by a
Governmental Authority having competent jurisdiction, to be in violation of the FCPA or any
of the restrictions imposed by OFAC, each other Developer shall have the right to terminate
this Agreement immediately, by providing a notice thereof setting forth the date of such
termination.

B-27

 

     11.03 AEI Termination Right. AEI shall have the right to terminate this Agreement by providing
thirty (30) days written notice to SES if: (a) SES is in breach of its representations or
covenants under Section 9.03; (b) SES or any of its Affiliates is made a party to any lawsuit in
which an assertion is made by a third party the use of the U-Gas Technology infringes any patents,
copyrights, trade secret rights or other intellectual property rights held by any such third party,
and such lawsuit is not dismissed within eighteen (18) months of its filing; or (c) with respect to
patents related to U-Gas Technology owned by SES or any of its Affiliates, any claims of such
patents are declared invalid by any court of competent jurisdiction, the United States Patent &
Trademark Office or any patent office of any country in which SES or any of its Affiliates own such
patents.

ARTICLE XII

MISCELLANEOUS PROVISIONS

     12.01 Notices. Except as otherwise specifically provided, all notices authorized or required
among the Developers by any of the provisions of this Agreement, shall be in writing, in English,
and delivered in person or by courier service or by any electronic means of transmitting written
communications which provides written confirmation of complete transmission, and addressed to such
Developers as designated below. Oral communication does not constitute notice for purposes of this
Agreement, and telephone numbers for the Developers are listed below as a matter of convenience
only. The originating notice given under any provision of this Agreement shall be deemed delivered
only when received by the Developer to whom such notice is directed, and the time for such
Developer to deliver any notice in response to such originating notice shall run from the date the
originating notice is received. The second or any responsive notice shall be deemed delivered when
received, which for purposes of this Section 12.01 shall mean actual delivery of the notice to the
address of the Developer to be notified specified in accordance with this Section 12.01. Each
Developer shall have the right to change its address at any time and/or designate that copies of
all such notices be directed to another person at another address, by giving written notice thereof
to each other Developer.

	 	 	 
	If to AEI:

	 	[Ashmore Energy International]
	 

	 	c/o AEI Services LLC
	 

	 	1221 Lamar Street, Suite 800
	 

	 	Houston, Texas 77010
	 

	 	ATTN: General Counsel
	 
	 	 
	With a copy to:

	 	Mr. Brian Bradshaw
	 

	 	Fulbright & Jaworski L.L.P.
	 

	 	Fulbright Tower
	 

	 	1301 McKinney, Suite 5100
	 

	 	Houston, Texas 77010

B-28

 

	 	 	 
	If to SES:

	 	[Synthesis Energy Systems, Inc.]
	 

	 	6330 West Loop South, Suite 300
	 

	 	Houston, Texas 77401
	 

	 	ATTN: Chief Executive Officer
	 
	 	 
	With a copy to:

	 	Mr. Robert Reedy
	 

	 	Porter & Hedges
	 

	 	1000 Main, 36th Floor
	 

	 	Houston, Texas 77002

     12.02 Governing Law. This Agreement shall be governed by, construed, interpreted, and applied
in accordance with the laws of New York, excluding any choice of law rules which would refer the
matter to the laws of another jurisdiction.

     12.03 Term. This Agreement shall be effective on the date hereof and shall remain in effect
until terminated by any Developer pursuant to any provision in this Agreement or by mutual
agreement of the Developers (the “Term”).

     12.04 Interest. If any amount payable under this Agreement is not paid on or before the date
due, the Developer liable for the payment also must pay interest at a rate per annum equal to the
Specified Rate on the amount not paid from and including the date it was due to, but excluding, the
date actually paid.

     12.05 Further Assurances. Each Developer shall take all additional actions and shall execute
all other and further instruments and documents as are necessary or appropriate to give full effect
to the provisions of this Agreement.

     12.06 No Further Relationship. The Developers agree that no Developer is the agent of any
other Developer and no such Person is authorized to take any action on behalf of the other, except
as expressly provided in this Agreement or a Project Contract.

     12.07 Binding Effect. All the terms of this Agreement shall be binding on and inure to the
benefit of the parties, their permitted successors-in-interest and permitted assigns.

     12.08 Assignment.

     (a) Unless otherwise agreed in a Project Contract or shareholder agreement, no
Developer shall directly or indirectly enter into any transaction for the disposition of any
of its interest in this Agreement or the Project without the prior written consent of each
other Developer, which consent may be withheld for any reason; provided, however, that any
parent entity of a Developer may mortgage, pledge, place a lien or charge (whether by way of
fixed or floating charge), grant a security interest, or otherwise encumber (whether
equitable or legal) as security for borrowed money any interest whether legal or beneficial
in a Developer, or in any entity between such parent entity and a Developer in the
respective Developer’s chain of ownership by giving notification thereof to each other
Developer.

B-29

 

     (b) The Developers acknowledge and agree that breach of this Section 12.08 may not be
compensable by payment of money damages and, therefore, if any dispute arises concerning the
disposition of all or any portion of any equity interest or its interest under this
Agreement, the Developers agree not to object to an injunction being issued on the
application of any Developer restraining such disposition or rescinding or suspending any
such disposition pending resolution of the dispute. Such remedies shall be cumulative and
non-exclusive and shall be in addition to any other rights and remedies the Developers may
have under this Agreement or at law.

     12.09 Specific Performance. The Developers acknowledge that the harm that would be caused by
a breach of this Agreement would be difficult, if not impossible, to calculate, and accordingly
each Developer and its Affiliates shall be entitled to injunctive relief to compel compliance with
the provisions of this Agreement, but nothing in this Section shall amend or modify Article VIII in
any respect.

     12.10 Entire Agreement. This Agreement constitutes the entire agreement of the parties and
their respective Affiliates relating to the subject matter of this Agreement and supersedes all
prior agreements and undertakings, oral or written, among the Developers with respect to the
subject matter of this Agreement, except for the Joint Development Agreement.

     12.11 Amendment. An amendment or modification of this Agreement shall be effective or binding
on the parties only if it is in writing and signed by all the Developers.

     12.12 Waivers. Any waiver, express or implied, by any Developer of any right under this
Agreement or of any breach by another Developer shall not constitute or be deemed as a waiver of
any other right or any other breach, whether of a similar or dissimilar nature to the right or
breach being waived. Failure on the part of a person to complain of any act of any person or to
declare any person in default, irrespective of how long that failure continues, does not constitute
a waiver by that person of its rights with respect to that default until the applicable
statute-of-limitations period has run. A waiver of a Shareholder’s rights under this Agreement
shall be effective only if that Shareholder agrees.

     12.13 No Third-Party Beneficiaries. Except as provided herein, this Agreement is solely for
the benefit of the Shareholders, the Project Company, and their respective permitted successors and
permitted assigns, and this Agreement shall not otherwise be deemed to confer upon or give to any
other third party, including any Lender or other creditor, any remedy, claim, liability,
reimbursement, cause of action or other right.

     12.14 Severability. If any of the provisions of this Agreement are held to be invalid or
unenforceable under the applicable law of any jurisdiction, the remaining provisions shall not be
affected, and any such invalidity or unenforceability shall not invalidate or render unenforceable
that provision in any other jurisdiction. In that event, the Shareholders and the Project Company
agree that the provisions of this Agreement shall be modified and reformed so as to effect the
original intent of the Shareholders and the Project Company as closely as possible with respect to
those provisions that were held to be invalid or unenforceable.

B-30

 

     12.15 Counterparts. This Agreement may be executed in two or more counterparts, each of which
shall be deemed an original, but all of which constitute but one agreement.

     12.16 Drafting Interpretation. Preparation of this Agreement has been a joint effort of all
the parties and the resulting document shall not be construed more severely against one of the
parties than against the others.

     12.17 Captions. Titles or captions of Sections or Articles contained in this Agreement are
inserted only as a matter of convenience and for reference, and in no way define, limit, extend or
describe the scope of this Agreement or the intent of any provision hereof.

     12.18 Governing Language. This Agreement has been drafted in English; the English version
shall prevail over any translations. The governing language of this Agreement shall be the English
language. Except as otherwise required by applicable law, all notices, correspondence,
information, literature, reports, data, manuals, procedures and other documents required under this
Agreement shall be in the English language.

     12.19 Counsel; Costs. Each Developer is represented by its own outside counsel and shall bear
its own costs in relation to the negotiation, preparation, and execution of this Agreement.

     IN WITNESS WHEREOF, the Developers have entered into this Agreement as of the day and year
first above written.

	 	 	 	 	 
	 	 	[ASHMORE ENERGY INTERNATIONAL]
	 
	 	 	 	 
	 

	 	By:
	 	                                                            
	 

	 	Name:
	 	                                                            
	 

	 	Title:
	 	                                                            
	 
	 	 	 	 
	 	 	[SYNTHESIS ENERGY SYSTEMS, INC.]
	 
	 	 	 	 
	 

	 	By:
	 	                                                            
	 

	 	Name:
	 	                                                            
	 

	 	Title:
	 	                                                            

B-31

 

Exhibit A

To The

Project Development Agreement

Project Description

Project Description

Describe the summary features of the transaction including:

	 	o	 	Project background/history
	 
	 	o	 	Counterparty (s) involved in the proposed project
	 
	 	o	 	Summary of terms and major issues
	 
	 	o	 	Study of target market

Initial Project Economics

Provide a summary valuation and return analysis that includes:

	 	o	 	Discounted cash flow analysis
	 
	 	o	 	Major value drivers and assumptions
	 
	 	o	 	Descriptions and results of sensitivities

Provide initial financial projections

	 	o	 	Income statement
	 
	 	o	 	Balance sheet
	 
	 	o	 	Cash flow statement
	 
	 	o	 	Any other relevant information (fees, royalties, etc)

Key Risks and Mitigants

Provide an overview of material transaction risks and potential mitigants, including those related
to :

	 	o	 	Permitting and approvals
	 
	 	o	 	Market pricing and demand
	 
	 	o	 	Construction and operations
	 
	 	o	 	Tax, accounting, and financing

Project Milestones

Proposed Lead Developer for the Project
Outline key milestones and events up to closing:

	 	o	 	Timing of expected contract discussions, licenses or site
acquisitions, and other key project stages
	 
	 	o	 	Future decision points, approvals, and all other material events

Budget and Resources

Provide detailed project development budget and required resources that includes:

	 	o	 	Estimated cost of all internal and external resources
	 
	 	o	 	Estimated timing of cash expenditures

Exhibit A - To The Project Development Agreement

A-1

 

Exhibit B

To The

Project Development Agreement

Development Services

1. Development Services to be Provided by AEI

	 	 	 	 	 	 
	 	 

	 	 	 	 
	 	 

	 	 	 	 
	 	 

	 	 	 	 
	 

2. Development Services to be Provided by SES

	 	 	 	 	 	 
	 	 

	 	 	 	 
	 	 

	 	 	 	 
	 	 

	 	 	 	 
	 

Reimbursement:

Exhibit B - To The Project Development Agreement

B-1

 

Exhibit C

To The

Project Development Agreement

Preliminary Timetable of Activities

Exhibit C - To The Project Development Agreement

C-1

 

Exhibit D

To The

Project Development Agreement

Development Budget

Exhibit D - To The Project Development Agreement

D-1

 

Exhibit E

To The

Project Development Agreement

Terms and Conditions of Equipment Supply

Set forth below is a summary of the terms and conditions that will be reflected in any Equipment
Supply Agreement by and between the Project Company and SES or one of its Affiliates. While the
Developers acknowledge and agree that any such Equipment Supply Agreement will contain additional
terms and conditions, it is the intent of the Developers that such Equipment Supply Agreement shall
contains terms and conditions substantially similar to the provisions set forth below.

     1. Scope. SES shall supply Equipment to each Project in accordance with the
Agreement, the Equipment Supply Agreement, and with the terms and conditions specified in this
Exhibit E.

     2. Equipment; Supply Schedule. A detailed description of (a) the Equipment to be
provided by SES for a Project; and (b) the schedule for such supply of Equipment to the Project,
including without limitation delivery dates for such Equipment, shall be set forth in the Project
Development Agreement for such Project or, in the event there is no Project Development Agreement
for a given Project, provided to SES as soon as reasonably practicable following a Developer’s
election to proceed with a Project, in each case unless otherwise agreed by SES and each Developer
participating in such Project. Regular updates to the Equipment supply schedule shall be provided
to SES as and when available.

     3. Price. The price paid by a Project Company for all Equipment provided by SES for
its respective Project shall be (i) the actual, reasonable, direct and necessary costs and expenses
incurred by SES to procure such Equipment, including without limitation shipping costs and fees
described in this Exhibit E and the Equipment Supply Agreement; plus (ii) a procurement fee equal
to forty percent (40%) of the purchase price paid by SES for such Equipment.

     4. Payment; Audit.

     (a) Payment for all Equipment provided by SES for a Project shall be due on the date
that falls ___ (___) days following the delivery by SES of the Equipment to the Project site
or the issuance by SES to the relevant Project Company of a written invoice setting forth a
detailed description of the costs incurred by SES for the procurement of each item of
Equipment and the corresponding price to be paid therefor by the Project Company or AEI, as
applicable.

     (b) Without prejudice to payment obligations hereunder, the relevant Project Company
and each Developer participating in a Project shall have the right, upon prior written
notice to SES, to inspect the written books and records of SES relating to the procurement
and supply of Equipment pursuant to the Agreement. Such inspection shall take place at the
head offices of SES.

Exhibit E - To The Project Development Agreement

E-1

 

     5. Late Payment. If any payment for Equipment that is due and payable to SES is not
received by the due date therefor, the Project Company shall pay interest to SES over the
outstanding amount of such payment at a rate equal to LIBOR plus 2.5% per annum, from the due date
until the date payment is actually received by SES.

     6. Tax Obligations.

     (a) SES shall be responsible for the payment of all taxes, duties, tariffs, fees,
imposts, excise, or other taxes imposed by any taxing authority with respect to any item of
Equipment prior to delivery thereof to a Project site. SES shall also assume all corporate
income taxes imposed upon it in connection with the sale of Equipment to a Project Company.

     (b) SES shall have no responsibility for the payment of any taxes, duties, tariffs,
fees, imposts, excise or other taxes imposed by any taxing authority with respect to the
ownership or use of any item of Equipment following the delivery thereof to a Project site.
In the event SES remits any such taxes or charges directly to such taxing authority or
authorities as may be required under the laws of any jurisdiction, such remittances shall be
for the account of the relevant Project Company and shall be reimbursed to SES within ___
(___) days following submission by SES of invoices and supporting documentation therefor.

     (c) All payments for Equipment made by a Project Company to SES shall be free and clear
of any deduction for taxes, assessments or other charges. However, if a Project Company
shall be required under the laws of any jurisdiction to withhold from any payment made to
SES any taxes, assessments or other charges which may be levied against such Project
Company, then the amount of the payment by such Project Company to SES for such Equipment
shall be increased so that the net amount received by SES will equal the full amount which
would have been received by it had no such deduction or withholding been made, and the
amount of any such tax, assessment or other charge shall be reimbursed by SES to the Project
Company within ___ (___) days following submission by that Project Company to SES of
invoices and supporting documentation therefor.

     7. Changes. A Project Company may at any time request changes to the Equipment to be
supplied by SES or the schedule for the supply of such Equipment or the delivery thereof to a
Project site, in each case by means of a written notice to SES.

     8. Warranty.

     (a) Warranty – Equipment. SES warrants that each item of Equipment supplied to
a Project Company hereunder will be new and free from defects in design, workmanship and
material and capable of operating in a Project (as used herein, the “Equipment Warranty”).
Such Equipment Warranty shall continue in effect until the date that is two (2) years
following the date on which such Equipment was delivered to the Project site (as used
herein, the “Equipment Warranty Period”).

Exhibit E - To The Project Development Agreement

E-2

 

     (b) Warranty – Spare Parts. Any spare part supplied by SES to a Project
Company under this agreement shall have a warranty identical to the Equipment Warranty,
except that the Equipment Warranty Period for such spare part shall expire either (i) one
(1) year after initial installation or usage thereof; or (ii) two (2) years after the date
of delivery of the spare part to the Project site, whichever first occurs.

     (c) Remedy for Nonconformity. If during the Equipment Warranty Period, a
Project Company notifies SES of any nonconformity of Equipment to the Equipment Warranty,
SES shall promptly remedy such nonconformity by repair, replacement or modification, as SES
deems necessary to correct such nonconformity. In the event that SES fails to remedy a
nonconformity within a reasonable period of time consistent with industry practice and
diligently pursue such remedy to completion, the Project Company may notify SES of its
intent to have a third party perform such remedy or repair, in which event SES shall
reimburse the Project Company for the Project Company’s actual, direct and reasonable costs
incurred in engaging a third party to remedy or repair the nonconformity. SES will not be
responsible for any nonconformity regarding, and the warranties provided in this Section 8
expressly exclude (i) any work performed by any third party in accordance with this section,
or (ii) Equipment that is adversely impacted or damaged due to work performed by any third
party in accordance with this section. Should investigation by SES reveal that there is no
nonconformity to the Equipment Warranty as reported by a Project Company, such Project
Company shall reimburse SES for its actual reasonable expense incurred in connection with
such investigation, any remedy or repair instigated, and any payment previously made by SES
to such Project Company for third party work.

     (d) Warranty on Remedy Work. Where any item of Equipment or part thereof is
repaired, replaced or modified pursuant to Section 8(c) above (except for work by a third
party, if any), said item or part shall be warranted to comply with the Equipment Warranty
for a period of two (2) years from the date of such remedy. In any event, the warranty
obligations of SES hereunder shall expire no later than two (2) years from the expiration
date of the original Equipment Warranty Period.

     9. Exclusivity of Warranties and Remedies. THE WARRANTIES PROVIDED HEREIN ARE
EXCLUSIVE AND NO OTHER WARRANTIES OF ANY KIND, WHETHER STATUTORY, EXPRESS OR IMPLIED (INCLUDING ALL
WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE, AND ALL WARRANTIES ARISING FROM
COURSE OF DEALING OR USAGE OF TRADE) SHALL APPLY. THE REMEDIES SET FORTH IN THIS AGREEMENT ARE THE
EXCLUSIVE REMEDIES OF ANY PROJECT COMPANY FOR ANY FAILURE BY SES TO COMPLY WITH ITS WARRANTY
OBLIGATIONS SPECIFIED HEREIN.

     10. Delivery and Title. Delivery of each item of Equipment shall be deemed to have
been made when such item arrives at the Project site. Title to each item of Equipment (other than
computer programs and software furnished by SES to a Project Company under the Agreement) shall
pass to the relevant Project Company when such item of Equipment arrives at the Project site.

Exhibit E - To The Project Development Agreement

E-3

 

     11. Risk of Loss. Risk of loss or damage to any item of Equipment shall be the
responsibility of SES until delivery thereof to the relevant Project site, at which point such risk
of loss or damage shall pass to the relevant Project Company. Notwithstanding the foregoing, SES
shall be responsible for any damage to the Equipment occurring during the period in which SES had
care, custody and control thereof, regardless of when such damage was identified or discovered.

     12. Title to Computer Software. Title to and the right of possession of any computer
programs or computer software provided by SES to a Project Company hereunder, if any, shall remain
with SES or its licensor, except that such Project Company shall have the right to possess and use
said computer programs or computer software for the purposes of completing, maintaining, adjusting,
operating, repairing and modifying the Equipment and/or the Project at no cost for the term of the
corresponding license provided herein. Nothing in this Agreement shall be construed as giving any
Project Company a right to sell, assign, lease or in any other manner transfer or encumber the
ownership of SES or its licensor of said computer programs or computer software, or as limiting SES
or its licensors from using and licensing the computer programs in any manner whatsoever.

     13. Shipment and Transportation. SES shall provide to the relevant Project Company
prior written notice of the scheduled dates for shipment and delivery of each item of Equipment to
the Project site. SES shall be responsible for the payment of all shipping and transportation
costs, including taxes and fees, which costs shall included in the calculation of the direct
procurement costs of such Equipment for purposes of Section 3 above.

     (a) In the event that such Project Company is unwilling or unable to receive the Equipment at
the time of delivery thereof, SES will, upon written notice to such Project Company and giving such
Project Company reasonable opportunity to designate a mutually acceptable alternate destination,
place such Equipment in an appropriate storage facility, at the expense of SES (which expenses
shall included in the calculation of the direct procurement costs of such Equipment for purposes of
Section 3 above). If the Equipment is placed into storage pursuant to this provision, delivery
thereof shall be deemed to have occurred. The Project Company shall arrange for the removal of
said Equipment from storage at such Project Company’s expense.

     (b) Unless otherwise requested in writing by the relevant Project Company, all shipments of
Equipment hereunder shall be by normal highway, rail, and/or ocean transport on normal routing from
the point of shipment to the Project site, in accordance with generally accepted industry practices
for the shipment of equipment that is similar in nature to the Equipment.

     14. Delay in Equipment Delivery. If the actual date of delivery of any Equipment is
later than the scheduled date of delivery thereof, due to a cause other than an event of Force
Majeure or the act or omission of the Project Company, SES shall pay to the relevant Project
Company liquidated damages, which shall not be included in the calculation of the direct
procurement costs of such Equipment for purposes of Section 3 above, calculated as follows:

Exhibit E - To The Project Development Agreement

E-4

 

     (a) SES shall pay liquidated damages at the rate of                      ($___) per day per item of
Equipment for the first thirty (30) days of delay; and

     (b) SES shall pay liquidated damages at the rate of                      ($___) per day per item of
Equipment for the next thirty (30) days of delay; and

     (c) SES shall pay liquidated damages at the rate of                      ($___) per day per item of
Equipment for each day of delay thereafter.

     15. Exclusive Remedies for Delay. THE REMEDIES OF A PROJECT COMPANY SET FORTH ABOVE
FOR THE FAILURE OF SES TO DELIVER EQUIPMENT BY ITS RESPECTIVE SCHEDULED DELIVERY DATES SHALL BE THE
SOLE AND EXCLUSIVE REMEDY OF SUCH PROJECT COMPANY FOR SUCH DELAY AND NO OTHER REMEDIES OF ANY KIND
WHATSOEVER SHALL APPLY; HOWEVER, THE FOREGOING SHALL NOT RELIEVE SES OF ITS OBLIGATION TO DELIVER
THE SAID EQUIPMENT.

     16. Performance Liquidated Damages. Liquidated damages for defects in the performance
of the Equipment, together with caps on those liquidated damages, will be discussed by the
Developers for each Project and included in the Equipment Supply Agreement.

     17. Insurance. SES shall effect and maintain at its own expense throughout the Term
of the Agreement, insurance policies with insurers and under forms of policies in types and amounts
consistent with internationally accepted industry standards and sufficient to insure the
performance of the Equipment supply, payment and warranty obligations of SES hereunder. Upon a
Project Company’s reasonable written request, SES shall provide to such Project Company
documentation evidencing the existence and amounts of such insurance coverage. For the avoidance
of doubt, insurance costs incurred by SES shall not be considered direct procurement costs for
purposes of Section 3.

     18. Licenses and Permits.

     (a) The relevant Project Company shall be responsible for all dealings with any governmental
authority regarding the Equipment upon and after the delivery thereof to the Project site,
including but not limited to obtaining and maintaining any licenses, permits and/or other
authorizations of any kind required for transportation, import, installation, maintenance, testing
or operation of such Equipment or any portion thereof. SES shall cooperate with such Project
Company and shall use reasonable efforts to provide all necessary information and documents and
otherwise assist such Project Company in connection with its efforts to obtain such licenses,
permits and authorizations. The relevant Project Company shall pay all costs of such licenses,
permits and authorizations and all costs and expenses incurred in obtaining and maintaining them,
including without limitation the reimbursement to SES of all reasonably incurred, direct and
necessary out-of-pocket costs which SES may incur in connection with the exercise of such
reasonable efforts. The obligation of such Project Company to pay for the Equipment shall not in
any manner be waived by the delay or failure to secure or renew, or by the cancellation of any
required licenses, permits or authorizations including any required import licenses.

Exhibit E - To The Project Development Agreement

E-5

 

     (b) SES shall be responsible for all dealings with any Governmental Authority (other than for
the import of the Equipment) that are necessary to fulfill the obligations of SES under the
Agreement, including but not limited to obtaining any licenses, permits and/or other authorizations
of any kind related to the manufacture and delivery of the Equipment, required for the
consolidation and export of the Equipment or the performance of any services in connection
therewith. For the avoidance of doubt, the Project Company shall be responsible for any
registration of the Agreement or any technology license with governmental authorities having
jurisdiction over the registration and protection of technology, intellectual property or
industrial property, as and when required.

Exhibit E - To The Project Development Agreement

E-6

 

Exhibit F

To The

Project Development Agreement

Termination and Release Agreement

(                     Project)

This Termination Agreement (this “Agreement”), dated as of [          ] , [___], 2007, is entered
into by and among ASHMORE ENERGY INTERNATIONAL (“AEI”), a corporation organized under the laws of
the Cayman Islands, and SYNTHESIS ENERGY SYSTEMS, INC. (“SES”), a corporation organized under the
laws of Delaware. Each of the signatories hereto is individually referred to herein as a
“Developer” and collectively as the “Developers”.

RECITALS

     A. AEI and SES are parties to a Joint Development Agreement, dated                     , 2007 (the
“JDA”).

     B. Pursuant to the terms of the JDA, the Developers agreed to undertake jointly the
development of that certain coal conversion project located in                      (the “Project”).

     C. Also pursuant to the JDA, the Developers entered into that certain Project Development
Agreement, dated                     , 20___, setting forth the terms and conditions of their participation in
the Project (the “PDA”).

     D. With effect on and from the delivery of written notice dated                     , 20___ (the
“Termination Date”),                                          wishes to withdraw and has withdrawn from the Project.

     E. In accordance with Section 6.01 of the PDA, the Developers wish to enter into this
Agreement to memorialize the terms and conditions of such withdrawal and to terminate the PDA.

     NOW, THEREFORE, in consideration of the mutual covenants contained herein and for other good
and valuable consideration, the sufficiency of which is hereby acknowledged, the parties hereto
agree as follows:

ARTICLE I

REPRESENTATIONS AND WARRANTIES

     Each Developer hereby represents and warrants to the other Developer as follows:

     1.1 Representations. Each Developer represents and warrants to the other Developer as
follows:

Exhibit F - To The Project Development Agreement

F-1

 

     (a) It is a duly organized, validly existing entity of the type described in the
preamble to this Agreement and (if applicable) is in good standing under the laws of the
jurisdiction of its formation and is duly qualified to do business and (if applicable) in
good standing as a foreign corporation in the jurisdiction of its principal place of
business (if not formed in that jurisdiction). It has all requisite power and authority to
enter into and to perform its obligations under this Agreement and has obtained (to the
extent applicable law permits the obtaining of same at this point in time) all approvals
from applicable governmental authorities necessary for it to enter into and to perform its
obligations under this Agreement.

     (b) Its execution, delivery, and performance of this Agreement have been duly
authorized by all necessary action on its part and that of its equity owners, and do not and
will not (a) violate any law, rule, regulation, order, or decree applicable to it or (b)
violate its organizational documents.

     (c) This Agreement is a legal and binding obligation of that Developer, enforceable
against that Developer in accordance with its terms, except to the extent enforceability is
modified by bankruptcy, reorganization and other similar laws affecting the rights of
creditors generally and by general principles of equity.

     (d) There is no litigation pending or, to the best of its knowledge, threatened to
which that Developer or any of its Affiliates is a party that could reasonably be expected
to have a material adverse effect on the financial condition, prospects, or business of that
Developer or its ability to perform its obligations under this Agreement.

     (e) The execution, delivery and performance of this Agreement will not conflict with,
violate or breach the terms of any agreement of that Developer or of any agreement to which
its properties are subject.

ARTICLE II

WITHDRAWAL FROM THE PROJECT AND THE PDA

     2.1 Effective as of the Termination Date,                      (a) has withdrawn from the development
of the Project, in accordance with Section 6.01 of the PDA and has and shall have no further
obligation to                      or with respect to the Project, except for (i) its share of costs incurred,
accrued, or otherwise contractually committed to the Project as of the Termination Date; (ii) the
survival of its confidentiality obligations pursuant to Section 7.04 of the PDA; and (iii) any
other obligations regarding the Project set forth in Article VI of the PDA; and (b) has no residual
interest or claim with respect to the Project; and (c) releases and transfers its equity interest
in the Project Company.

     2.2 Effective as of the date of this Agreement, (a)                      withdraws from the PDA, (b)
the PDA is hereby terminated with respect to                     , and (c)                      has no residual interest
or claim with respect to the PDA.

     2.3 This Agreement shall be deemed to be the “Termination and Release Agreement” required to
be executed by the Developers pursuant to Section 6.01 of the PDA.

Exhibit F - To The Project Development Agreement

F-2

 

     2.4 Other than with respect to the obligations set forth in Section 2.1 above, each Developer
hereby fully and forever releases and discharges each other Developer and its Affiliates from and
of any and all obligations of any kind relating to the Project and/or the PDA. Each Developer
hereby further agrees that it will not seek to bring any action of any kind against any other
Developer or any of its Affiliates to seek to enforce any released obligation or any other
obligation arising out of or in connection with the Project and/or the PDA.

ARTICLE III

NOTICES

     Except as otherwise specifically provided, all notices authorized or required among the
Developers by any of the provisions of this Agreement, shall be in writing, in English, and
delivered in person or by courier service or by any electronic means of transmitting written
communications which provides written confirmation of complete transmission, and addressed to such
Developers as designated below. Oral communication does not constitute notice for purposes of this
Agreement, and telephone numbers for the Developers are listed below as a matter of convenience
only. The originating notice given under any provision of this Agreement shall be deemed delivered
only when received by the Developer to whom such notice is directed, and the time for such
Developer to deliver any notice in response to such originating notice shall run from the date the
originating notice is received. The second or any responsive notice shall be deemed delivered when
received, which for purposes of this Article IV shall mean actual delivery of the notice to the
address of the Developer to be notified specified in accordance with this Article IV. Each
Developer shall have the right to change its address at any time and/or designate that copies of
all such notices be directed to another person at another address, by giving written notice thereof
to the other Developers.

	 	 	 
	If to AEI:

	 	[Ashmore Energy International]
	 

	 	/o AEI Services LLC
	 

	 	1221 Lamar Street, Suite 800
	 

	 	Houston, Texas 77010
	 

	 	ATTN: General Counsel
	 
	 	 
	With a copy to:

	 	Mr. Brian Bradshaw
	 

	 	Fulbright Tower
	 

	 	Fulbright & Jaworski L.L.P.
	 

	 	1301 McKinney, Suite 5100
	 

	 	Houston, Texas 77010
	 
	 	 
	If to SES:

	 	[Synthesis Energy Systems, Inc.]
	 

	 	330 West Loop South, Suite 300
	 

	 	Houston, Texas 77401
	 

	 	ATTN: Chief Executive Officer
	 
	 	 
	With a copy to:

	 	Mr. Robert Reedy
	 

	 	Porter & Hedges
	 

	 	1000 Main, 36th Floor
	 

	 	Houston, Texas 77002

Exhibit F - To The Project Development Agreement

F-3

 

ARTICLE IV

MISCELLANEOUS

     4.1 Survival of Representations and Warranties.

     Each of the representations and warranties made herein shall terminate and cease to be of
further force or effect after the date of the execution of this Agreement, and there shall be no
liability in respect thereof, whether such liability has accrued prior to or after the date hereof,
on the part of any Developer or any of its officers, directors, employees, agents or Affiliates.

     4.2 No Consequential or Punitive Damages.

     The Developers shall only be liable hereunder for direct or compensatory damages. No
Developer (or its Affiliates) shall, under any circumstance, be liable to any other Developer (or
its Affiliates) for any indirect, consequential, exemplary, special, incidental, punitive or moral
damages or lost revenue, lost income, lost profits, lucro cessante, cost of capital or loss of
business reputation or opportunity claimed by such other Developer under the terms of or due to any
breach of this Agreement.

     4.3 Agreement to Arbitrate.

     Any and all disputes, controversies or claims arising out of or relating to this Agreement, or
the termination, validity or alleged breach thereof, or any indemnification claim hereunder, or in
any way relating to the subject matter of this Agreement or the relationship among the Developers
created by this Agreement shall be resolved in accordance with the provisions of Article X of the
JDA.

     4.4 Entire Agreement; Amendments and Waivers.

     This Agreement and the JDA represent the entire understanding and agreement among the
Developers with respect to the subject matter hereof, and can be amended, supplemented or changed,
and any provision hereof can be waived, only by a written instrument making specific reference to
this Agreement signed by each of the Developers. No action taken pursuant to this Agreement,
including any investigation by or on behalf of any Developer, shall be deemed to constitute a
waiver by the Developer taking such action of compliance with any representation, warranty,
covenant or agreement contained herein. The waiver by any Developer of a breach of any provision
of this Agreement shall not operate or be construed as a further or continuing waiver of such
breach or as a waiver of any other or subsequent breach. No failure on the part of any Developer
to exercise, and no delay in exercising, any right, power or remedy hereunder shall operate as a
waiver thereof, nor shall any single or partial exercise of such right, power or remedy by such
Developer preclude any other or further exercise thereof or the exercise of any other right, power
or remedy. Unless specifically set forth herein to the contrary, all remedies hereunder are
cumulative and are not exclusive of any other remedies provided by Law.

Exhibit F - To The Project Development Agreement

F-4

 

     4.5 Governing Law.

     THIS AGREEMENT, THE RIGHTS AND OBLIGATIONS OF THE DEVELOPERS UNDER THIS AGREEMENT, AND ANY
CLAIM OR CONTROVERSY DIRECTLY OR INDIRECTLY BASED UPON OR ARISING OUT OF THIS AGREEMENT OR THE
TRANSACTIONS CONTEMPLATED BY THIS AGREEMENT (WHETHER BASED ON CONTRACT, TORT OR ANY OTHER THEORY),
INCLUDING ALL MATTERS OF CONSTRUCTION, VALIDITY AND PERFORMANCE, SHALL IN ALL RESPECTS BE GOVERNED
BY AND INTERPRETED, CONSTRUED AND DETERMINED IN ACCORDANCE WITH THE LAWS OF NEW YORK (WITHOUT
REGARD TO ANY CONFLICTS OF LAW PROVISION THAT WOULD REQUIRE THE APPLICATION OF THE LAW OF ANY OTHER
JURISDICTION). IT IS UNDERSTOOD THAT THE CHOICE OF THE LAW OF NEW YORK TO GOVERN THIS AGREEMENT
DOES NOT IN ANY WAY CONSTITUTE THE CONSENT OF ANY PARTY OR OF ANY AFFILIATE THEREOF TO THE
JURISDICTION OF ANY PARTICULAR COURT.

     4.6 No Oral Modifications.

     This Agreement may not be amended or modified except by written agreement signed by each of
the Developers.

     4.7 Severability.

     If any provision of this Agreement is invalid or unenforceable, the balance of this Agreement
shall remain in effect. If any provision of this Agreement is invalid or unenforceable, the
Developers agree that the provisions of this Agreement shall be modified and reformed by the
Developers so as to effect the original intent of the Developers as closely as possible with
respect to those provisions that were held to be invalid or unenforceable.

     4.8 Binding Effect; Assignment.

     This Agreement shall be binding upon and inure to the benefit of the Developers and their
respective successors and permitted assigns, including any trustee or other fiduciary appointed as
legal representative thereof. The Developers may not assign this Agreement or any rights or
obligations hereunder, except whether by operation of law or otherwise, without the prior written
consent of the other Developers and any attempted assignment without the required consents shall be
void.

     4.9 Publicity.

     Neither of the Developers, nor any of their respective Affiliates, agents or representatives,
shall issue any press release or public statement concerning this Agreement or the transactions
contemplated hereby without obtaining the prior written consent of the other Developers, in the
case of a disclosure by any other Developer, unless such disclosure is required by Applicable Law
or obligations pursuant to any agreement with any national securities exchange; provided, that the
Developer intending to make such release shall give the other Developers prior notice and shall use
its best efforts consistent with such Applicable Law, Order or obligation to consult with the other
Developers with respect to the text thereof.

Exhibit F - To The Project Development Agreement

F-5

 

     4.10 Use of Name

     Notwithstanding any provision herein to the contrary, following the execution of this
Agreement, no Developer shall have the right to make reference to, or otherwise use the name of the
other Developer or any of its Affiliates in connection with the Project or the PDA without the
prior written consent of such party.

     4.11 Continuation of the JDA.

     The JDA shall remain in full force and effect, and the validity and binding effect thereof
with respect to the Developers shall not be affected by their execution, delivery or performance of
this Agreement, except as otherwise expressly set forth herein.

     4.12 Counterparts.

     This Agreement may be executed in any number of counterparts, each of which will be deemed an
original, but all of which together will constitute one and the same instrument.

     4.13 Capitalized Terms.

     Capitalized terms that are used but not defined herein have the meanings given them in the
JDA.

     IN WITNESS WHEREOF, this Agreement has been executed by the duly authorized representatives of
the Developers as of the day and year first above-written.

	 	 	 	 	 	 	 
	 	 	ASHMORE ENERGY INTERNATIONAL
	 
	 	 	 	 	 	 
	 

	 	By:	 	 	 	 
	 

	 	 	 	 	 	 
	 

	 	Name:	 	 	 	 
	 

	 	 	 	 	 	 
	 

	 	Title:	 	 	 	 
	 

	 	 	 	 	 	 
	 
	 	 	 	 	 	 
	 	 	SYNTHESIS ENERGY SYSTEMS, INC.
	 
	 	 	 	 	 	 
	 

	 	By:	 	 	 	 
	 

	 	 	 	 	 	 
	 

	 	Name:	 	 	 	 
	 

	 	 	 	 	 	 
	 

	 	Title:	 	 	 	 
	 

	 	 	 	 	 	 

Exhibit F - To The Project Development Agreement

F-6

 

Exhibit “C”

Terms and Conditions of Equipment Supply

     Set forth below is a summary of the terms and conditions that will be reflected in any
Equipment Supply Agreement that is executed between SES and a Project Company for the provision of
Equipment to a Project. While the Developers acknowledge and agree that any such Equipment Supply
Agreement will contain additional terms and conditions, it is the intent of the Developers that
such Equipment Supply Agreement shall contains terms and conditions substantially similar to the
provisions set forth below.

     1. Scope. SES shall supply Equipment to each Project in accordance with the
Agreement, the Equipment Supply Agreement, and with the terms and conditions specified in this
Exhibit E.

     2. Equipment; Supply Schedule. A detailed description of (a) the Equipment to be
provided by SES for a Project; and (b) the schedule for such supply of Equipment to the Project,
including without limitation delivery dates for such Equipment, shall be set forth in the Project
Development Agreement for such Project or, in the event there is no Project Development Agreement
for a given Project, provided to SES as soon as reasonably practicable following a Developer’s
election to proceed with a Project, in each case unless otherwise agreed by SES and each Developer
participating in such Project. Regular updates to the Equipment supply schedule shall be provided
to SES as and when available.

     3. Price. The price paid by a Project Company for all Equipment provided by SES for
its respective Project shall be (i) the actual, reasonable, direct and necessary costs and expenses
incurred by SES to procure such Equipment, including without limitation shipping costs and fees
described in this Exhibit E and the Equipment Supply Agreement; plus (ii) a procurement fee
equal to forty percent (40%) of the purchase price paid by SES for such Equipment.

     4. Payment; Audit.

     (a) Payment for all Equipment provided by SES for a Project shall be due on the date
that falls            (___) days following the delivery by SES of the Equipment to the Project site
or the issuance by SES to the relevant Project Company of a written invoice setting forth a
detailed description of the costs incurred by SES for the procurement of each item of
Equipment and the corresponding price to be paid therefor by the Project Company or AEI, as
applicable.

     (b) Without prejudice to payment obligations hereunder, the relevant Project Company
and each Developer participating in a Project shall have the right, upon prior written
notice to SES, to inspect the written books and records of SES relating to the procurement
and supply of Equipment pursuant to the Agreement. Such inspection shall take place at the
head offices of SES.

C-1

 

     5. Late Payment. If any payment for Equipment that is due and payable to SES is not
received by the due date therefor, the Project Company shall pay interest to SES over the
outstanding amount of such payment at a rate equal to LIBOR plus 2.5% per annum, from the due date
until the date payment is actually received by SES.

     6. Tax Obligations.

     (a) SES shall be responsible for the payment of all taxes, duties, tariffs, fees,
imposts, excise, or other taxes imposed by any taxing authority with respect to any item of
Equipment prior to delivery thereof to a Project site. SES shall also assume all corporate
income taxes imposed upon it in connection with the sale of Equipment to a Project Company.

     (b) SES shall have no responsibility for the payment of any taxes, duties, tariffs,
fees, imposts, excise or other taxes imposed by any taxing authority with respect to the
ownership or use of any item of Equipment following the delivery thereof to a Project site.
In the event SES remits any such taxes or charges directly to such taxing authority or
authorities as may be required under the laws of any jurisdiction, such remittances shall be
for the account of the relevant Project Company and shall be reimbursed to SES within           
(___) days following submission by SES of invoices and supporting documentation therefor.

     (c) All payments for Equipment made by a Project Company to SES shall be free and clear
of any deduction for taxes, assessments or other charges. However, if a Project Company
shall be required under the laws of any jurisdiction to withhold from any payment made to
SES any taxes, assessments or other charges which may be levied against such Project
Company, then the amount of the payment by such Project Company to SES for such Equipment
shall be increased so that the net amount received by SES will equal the full amount which
would have been received by it had no such deduction or withholding been made, and the
amount of any such tax, assessment or other charge shall be reimbursed by SES to the Project
Company within            (___) days following submission by that Project Company to SES of
invoices and supporting documentation therefor.

     7. Changes. A Project Company may at any time request changes to the Equipment to be
supplied by SES or the schedule for the supply of such Equipment or the delivery thereof to a
Project site, in each case by means of a written notice to SES.

     8. Warranty.

     (a) Warranty – Equipment. SES warrants that each item of Equipment supplied to
a Project Company hereunder will be new and free from defects in design, workmanship and
material and capable of operating in a Project (as used herein, the “Equipment Warranty”).
Such Equipment Warranty shall continue in effect until the date that is two (2) years
following the date on which such Equipment was delivered to the Project site (as used
herein, the “Equipment Warranty Period”).

C-2

 

     (b) Warranty – Spare Parts. Any spare part supplied by SES to a Project
Company under this agreement shall have a warranty identical to the Equipment Warranty,
except that the Equipment Warranty Period for such spare part shall expire either (i) one
(1) year after initial installation or usage thereof; or (ii) two (2) years after the date
of delivery of the spare part to the Project site, whichever first occurs.

     (c) Remedy for Nonconformity. If during the Equipment Warranty Period, a
Project Company notifies SES of any nonconformity of Equipment to the Equipment Warranty,
SES shall promptly remedy such nonconformity by repair, replacement or modification, as SES
deems necessary to correct such nonconformity. In the event that SES fails to remedy a
nonconformity within a reasonable period of time consistent with industry practice and
diligently pursue such remedy to completion, the Project Company may notify SES of its
intent to have a third party perform such remedy or repair, in which event SES shall
reimburse the Project Company for the Project Company’s actual, direct and reasonable costs
incurred in engaging a third party to remedy or repair the nonconformity. SES will not be
responsible for any nonconformity regarding, and the warranties provided in this Section 8
expressly exclude (i) any work performed by any third party in accordance with this section,
or (ii) Equipment that is adversely impacted or damaged due to work performed by any third
party in accordance with this section. Should investigation by SES reveal that there is no
nonconformity to the Equipment Warranty as reported by a Project Company, such Project
Company shall reimburse SES for its actual reasonable expense incurred in connection with
such investigation, any remedy or repair instigated, and any payment previously made by SES
to such Project Company for third party work.

     (d) Warranty on Remedy Work. Where any item of Equipment or part thereof is
repaired, replaced or modified pursuant to Section 8(c) above (except for work by a third
party, if any), said item or part shall be warranted to comply with the Equipment Warranty
for a period of two (2) years from the date of such remedy. In any event, the warranty
obligations of SES hereunder shall expire no later than two (2) years from the expiration
date of the original Equipment Warranty Period.

     9. Exclusivity of Warranties and Remedies. THE WARRANTIES PROVIDED HEREIN ARE
EXCLUSIVE AND NO OTHER WARRANTIES OF ANY KIND, WHETHER STATUTORY, EXPRESS OR IMPLIED (INCLUDING ALL
WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE, AND ALL WARRANTIES ARISING FROM
COURSE OF DEALING OR USAGE OF TRADE) SHALL APPLY. THE REMEDIES SET FORTH IN THIS AGREEMENT ARE THE
EXCLUSIVE REMEDIES OF ANY PROJECT COMPANY FOR ANY FAILURE BY SES TO COMPLY WITH ITS WARRANTY
OBLIGATIONS SPECIFIED HEREIN.

     10. Delivery and Title. Delivery of each item of Equipment shall be deemed to have
been made when such item arrives at the Project site. Title to each item of Equipment (other than
computer programs and software furnished by SES to a Project Company under the Agreement) shall
pass to the relevant Project Company when such item of Equipment arrives at the Project site.

C-3

 

     11. Risk of Loss. Risk of loss or damage to any item of Equipment shall be the
responsibility of SES until delivery thereof to the relevant Project site, at which point such risk
of loss or damage shall pass to the relevant Project Company. Notwithstanding the foregoing, SES
shall be responsible for any damage to the Equipment occurring during the period in which SES had
care, custody and control thereof, regardless of when such damage was identified or discovered.

     12. Title to Computer Software. Title to and the right of possession of any computer
programs or computer software provided by SES to a Project Company hereunder, if any, shall remain
with SES or its licensor, except that such Project Company shall have the right to possess and use
said computer programs or computer software for the purposes of completing, maintaining, adjusting,
operating, repairing and modifying the Equipment and/or the Project at no cost for the term of the
corresponding license provided herein. Nothing in this Agreement shall be construed as giving any
Project Company a right to sell, assign, lease or in any other manner transfer or encumber the
ownership of SES or its licensor of said computer programs or computer software, or as limiting SES
or its licensors from using and licensing the computer programs in any manner whatsoever.

     13. Shipment and Transportation. SES shall provide to the relevant Project Company
prior written notice of the scheduled dates for shipment and delivery of each item of Equipment to
the Project site. SES shall be responsible for the payment of all shipping and transportation
costs, including taxes and fees, which costs shall included in the calculation of the direct
procurement costs of such Equipment for purposes of Section 3 above.

     (a) In the event that such Project Company is unwilling or unable to receive the
Equipment at the time of delivery thereof, SES will, upon written notice to such Project
Company and giving such Project Company reasonable opportunity to designate a mutually
acceptable alternate destination, place such Equipment in an appropriate storage facility,
at the expense of SES (which expenses shall included in the calculation of the direct
procurement costs of such Equipment for purposes of Section 3 above). If the Equipment is
placed into storage pursuant to this provision, delivery thereof shall be deemed to have
occurred. The Project Company shall arrange for the removal of said Equipment from storage
at such Project Company’s expense.

     (b) Unless otherwise requested in writing by the relevant Project Company, all
shipments of Equipment hereunder shall be by normal highway, rail, and/or ocean transport on
normal routing from the point of shipment to the Project site, in accordance with generally
accepted industry practices for the shipment of equipment that is similar in nature to the
Equipment.

     14. Delay in Equipment Delivery. If the actual date of delivery of any Equipment is
later than the scheduled date of delivery thereof, due to a cause other than an event of Force
Majeure or the act or omission of the Project Company, SES shall pay to the relevant Project
Company liquidated damages, which shall not be included in the calculation of the direct
procurement costs of such Equipment for purposes of Section 3 above, calculated as follows:

C-4

 

     (a) SES shall pay liquidated damages at the rate of                      ($           ) per day per
item of Equipment for the first thirty (30) days of delay; and

     (b) SES shall pay liquidated damages at the rate of                      ($           ) per day per
item of Equipment for the next thirty (30) days of delay; and

     (c) SES shall pay liquidated damages at the rate of                      ($           ) per day per
item of Equipment for each day of delay thereafter. [Note: Are there any performance LDs]

     15. Exclusive Remedies for Delay. THE REMEDIES OF A PROJECT COMPANY SET FORTH ABOVE
FOR THE FAILURE OF SES TO DELIVER EQUIPMENT BY ITS RESPECTIVE SCHEDULED DELIVERY DATES SHALL BE THE
SOLE AND EXCLUSIVE REMEDY OF SUCH PROJECT COMPANY FOR SUCH DELAY AND NO OTHER REMEDIES OF ANY KIND
WHATSOEVER SHALL APPLY; HOWEVER, THE FOREGOING SHALL NOT RELIEVE SES OF ITS OBLIGATION TO DELIVER
THE SAID EQUIPMENT.

     16. Performance Liquidated Damages. Liquidated damages for defects in the performance
of the Equipment, together with caps on those liquidated damages, will be discussed by the
Developers for each Project and included in the Equipment Supply Agreement.

     17. Insurance. SES shall effect and maintain at its own expense throughout the Term
of the Agreement, insurance policies with insurers and under forms of policies in types and amounts
consistent with internationally accepted industry standards and sufficient to insure the
performance of the Equipment supply, payment and warranty obligations of SES hereunder. Upon a
Project Company’s reasonable written request, SES shall provide to such Project Company
documentation evidencing the existence and amounts of such insurance coverage. For the avoidance
of doubt, insurance costs incurred by SES shall not be considered direct procurement costs for
purposes of Section 3.

     18. Licenses and Permits.

     (a) The relevant Project Company shall be responsible for all dealings with any
governmental authority regarding the Equipment upon and after the delivery thereof to the
Project site, including but not limited to obtaining and maintaining any licenses, permits
and/or other authorizations of any kind required for transportation, import, installation,
maintenance, testing or operation of such Equipment or any portion thereof. SES shall
cooperate with such Project Company and shall use reasonable efforts to provide all
necessary information and documents and otherwise assist such Project Company in connection
with its efforts to obtain such licenses, permits and authorizations. The relevant Project
Company shall pay all costs of such licenses, permits and authorizations and all costs and
expenses incurred in obtaining and maintaining them, including without limitation the
reimbursement to SES of all reasonably incurred, direct and necessary out-of-pocket costs
which SES may incur in connection with the exercise of such reasonable efforts. The
obligation of such Project Company to pay for the Equipment shall not in any manner be
waived by the delay or

C-5

 

failure to secure or renew, or by the cancellation of any required licenses, permits or
authorizations including any required import licenses.

     (b) SES shall be responsible for all dealings with any Governmental Authority (other than for the
import of the Equipment) that are necessary to fulfill the obligations of SES under the Agreement,
including but not limited to obtaining any licenses, permits and/or other authorizations of any
kind related to the manufacture and delivery of the Equipment, required for the consolidation and
export of the Equipment or the performance of any services in connection therewith. For the
avoidance of doubt, the Project Company shall be responsible for any registration of the Agreement
or any technology license with governmental authorities having jurisdiction over the registration
and protection of technology, intellectual property or industrial property, as and when
required.

C-6

 

Schedule 1.19

     For the purposes hereof, Emerging Markets shall mean all countries other than the ones
set forth below:

Australia

Austria

Belgium

Canada

Denmark

Finland

France

Germany

Greenland

Iceland

Ireland

Italy

Japan

Liechtenstein

Luxemburg

Monaco

Netherlands

New Zealand

Norway

Portugal

Spain

Sweden

Switzerland

United Kingdom

United States

Schedule 1.19

 

 

Schedule 1.38

Set forth below is a list of Pre-Existing Projects.

Hai Hua. On October 22, 2006, SES signed a co-operative joint venture contract
with Shandong Hai Hua Coal & Chemical Company Ltd. (“Hai Hua”) for the
development, construction and operation of an approximately $25 million SynGas
production plant utilizing U-GAS® technology in Zaozhuang City, Shandong
Province in China, as well as a contract for the purchase and sale of SynGas
and other gasification byproducts (ash, elemental sulfur, hydrogen and argon).
The plant is designed to produce approximately 28,000 standard cubic meters per
hour of gross SynGas. Hai Hua has contracted to pay a monthly capacity fee,
and, subject to delivery, a monthly energy fee, to the joint venture once the
production facility is complete.

Golden Concord. On May 25, 2007, SES executed a co-operative joint venture
contract with Inner Mongolia Golden Concord (Xilinhot) Energy Investment Co.,
Ltd. (“Golden Concord”), a subsidiary of one of China’s largest independent
private power producers, to develop, construct, operate, and manage an
approximately $96 million coal gasification, methanol and DME production plant
utilizing the U-GAS® technology to process low quality, high ash lignite coals
made available from Golden Concord’s coal mine in Xilinguole, Inner Mongolia
and other mines in the area. The facility is expected to produce SynGas which
will be used as a feedstock for a 225,000 ton per year methanol plant and, in
turn, a 150,000 ton per year DME plant.

YIMA. On May 3, 2007, SES entered into a non-binding preliminary
co-operative agreement with YIMA Coal Industry Group Co. Ltd. (“YIMA”), a
company partially owned by the Chinese government, for the construction of an
approximately $250-$350 million integrated coal-to-methanol (ultimately into
DME) plant in Henan Province, China. When completed, the plant is expected to
have an hourly capacity of approximately 360,000 standard cubic meters of gross
SynGas and an annual capacity of 1 million tons of methanol or 660,000 tons of
DME. The estimated total cost represents the estimated capital expenditures for
both the gasification and methanol/DME portions of the plant.

Schedule 1.38exv10w4

 

EXHIBIT 10.4

FORM OF

AMENDED AND RESTATED

ADMINISTRATIVE SERVICES AGREEMENT

AMONG

ENCORE ENERGY PARTNERS GP LLC,

ENCORE ENERGY PARTNERS LP,

ENCORE ENERGY PARTNERS OPERATING LLC,

AND

ENCORE OPERATING, L.P.

 

 

TABLE OF CONTENTS

	 	 	 	 	 	 	 
	ARTICLE I DEFINITIONS	 	 	1	 
	 
	 	 	 	 	 	 
	Section 1.1
	 	Definitions	 	 	1	 
	Section 1.2
	 	Construction	 	 	4	 
	 
	 	 	 	 	 	 
	ARTICLE II RETENTION OF ENCORE OPERATING; SCOPE OF SERVICES	 	 	4	 
	 
	 	 	 	 	 	 
	Section 2.1
	 	Retention of Encore Operating	 	 	4	 
	Section 2.2
	 	Scope of Services	 	 	5	 
	Section 2.3
	 	Exclusion of Services	 	 	5	 
	Section 2.4
	 	Performance of Services by Affiliates and Third Parties	 	 	5	 
	Section 2.5
	 	Intellectual Property	 	 	5	 
	Section 2.6
	 	Appointment of Independent Accounting Firm and Independent Petroleum Engineer	 	 	6	 
	 
	 	 	 	 	 	 
	ARTICLE III BOOKS, RECORDS AND REPORTING	 	 	6	 
	 
	 	 	 	 	 	 
	Section 3.1
	 	Books and Records	 	 	6	 
	Section 3.2
	 	Audits	 	 	6	 
	Section 3.3
	 	Reports	 	 	6	 
	 
	 	 	 	 	 	 
	ARTICLE IV PAYMENT AMOUNT	 	 	6	 
	 
	 	 	 	 	 	 
	Section 4.1
	 	Payment Amount	 	 	6	 
	Section 4.2
	 	Payment of Payment Amount	 	 	7	 
	Section 4.3
	 	Disputed Charges	 	 	7	 
	Section 4.4
	 	Set Off	 	 	7	 
	Section 4.5
	 	Encore Operating’s Employees	 	 	8	 
	Section 4.6
	 	Approval of Expenses	 	 	8	 
	 
	 	 	 	 	 	 
	ARTICLE V FORCE MAJEURE	 	 	8	 
	 
	 	 	 	 	 	 
	ARTICLE VI ASSIGNMENTS AND SUBCONTRACTS	 	 	9	 
	 
	 	 	 	 	 	 
	Section 6.1
	 	Assignments	 	 	9	 
	Section 6.2
	 	Other Requirements	 	 	9	 
	 
	 	 	 	 	 	 
	ARTICLE VII TERMINATION	 	 	10	 
	 
	 	 	 	 	 	 
	Section 7.1
	 	Termination by the Partnership on behalf of the Partnership Group	 	 	10	 
	Section 7.2
	 	Termination by Encore Operating	 	 	10	 
	Section 7.3
	 	Effect of Termination	 	 	10	 
	 
	 	 	 	 	 	 
	ARTICLE VIII CONFIDENTIAL INFORMATION	 	 	11	 
	 
	 	 	 	 	 	 
	Section 8.1
	 	Nondisclosure	 	 	11	 
	Section 8.2
	 	Permitted Disclosure	 	 	11	 

i

 

	 	 	 	 	 	 	 
	 
	 	 	 	 	 	 
	ARTICLE IX LIMITATION OF LIABILITY; INDEMNIFICATION	 	 	12	 
	 
	 	 	 	 	 	 
	Section 9.1
	 	Limitation of Encore Operating’s Liability	 	 	12	 
	Section 9.2
	 	Partnership’s Indemnity	 	 	12	 
	Section 9.3
	 	Limitation of Damages	 	 	12	 
	Section 9.4
	 	Affiliate; Third Parties	 	 	12	 
	 
	 	 	 	 	 	 
	ARTICLE X DISPUTE RESOLUTION	 	 	12	 
	 
	 	 	 	 	 	 
	ARTICLE XI GENERAL PROVISIONS	 	 	12	 
	 
	 	 	 	 	 	 
	Section 11.1
	 	Notices	 	 	12	 
	Section 11.2
	 	Further Action	 	 	13	 
	Section 11.3
	 	Binding Effect	 	 	13	 
	Section 11.4
	 	Integration	 	 	13	 
	Section 11.5
	 	Creditors	 	 	13	 
	Section 11.6
	 	Waiver	 	 	13	 
	Section 11.7
	 	Counterparts	 	 	13	 
	Section 11.8
	 	Applicable Law	 	 	14	 
	Section 11.9
	 	Invalidity of Provisions	 	 	14	 
	Section 11.10
	 	Amendment or Restatement	 	 	14	 
	Section 11.11
	 	Directly or Indirectly	 	 	14	 

ii

 

AMENDED AND RESTATED

ADMINISTRATIVE SERVICES AGREEMENT

     THIS AMENDED AND RESTATED ADMINISTRATIVE SERVICES AGREEMENT is entered into on, and effective
as of _________, 2007 (the “Effective Date”), among Encore Energy Partners GP LLC, a Delaware
limited liability company (the “General Partner”), Encore Energy Partners LP, a Delaware limited
partnership (the “Partnership”), Encore Energy Partners Operating LLC, a Delaware limited liability
company (the “Operating Company”), and Encore Operating, L.P., a Texas limited partnership (“Encore
Operating,” and collectively with the General Partner, the Partnership and the Operating Company,
the “Parties” and each, a “Party”), and amends and restates in its entirety the Administrative
Services Agreement dated as of March 7, 2007.

RECITALS

     A. The Partnership is the owner, directly or indirectly, of interests in the Business (as
hereinafter defined);

     B. The Partnership Group (as hereinafter defined) requires certain services to operate the
Business and to fulfill other general and administrative functions relating to the Business; and

     C. The Partnership Group desires that Encore Operating provide such services, and Encore
Operating is willing to undertake such engagement, subject to the terms and conditions of this
Agreement;

     NOW, THEREFORE, the General Partner, the Partnership, the Operating Company and Encore
Operating agree as follows:

ARTICLE I

DEFINITIONS

     Section 1.1 Definitions. The following definitions shall be for all purposes, unless otherwise clearly indicated to the
contrary, applied to the terms used in this Agreement.

     “Administrative Fee” is defined in Section 4.1.

     “Affiliate” means, with respect to any Person, any other Person that directly or indirectly
through one or more intermediaries controls, is controlled by or is under common control with, the
Person in question. As used herein, the term “control” means the possession, direct or indirect, of
the power to direct or cause the direction of the management and policies of a Person, whether
through ownership of voting securities, by contract or otherwise.

     “Agreement” means this Amended and Restated Administrative Services Agreement, as it may be
amended, supplemented or restated from time to time.

     “Bankrupt” with respect to any Person means such Person shall generally be unable to pay its
debts as such debts become due, or shall so admit in writing or shall make a general

 

 

assignment for the benefit of creditors; or any proceeding shall be instituted by or against such Person seeking
to adjudicate it a bankrupt or insolvent, or seeking liquidation, winding up, reorganization,
arrangement, adjustment, protection, relief, or composition of it or its debts under any law
relating to bankruptcy, insolvency or reorganization or relief of debtors, or seeking the entry of
an order for relief or the appointment of a receiver, trustee, or other similar official for it or
for any substantial part of its property and, in the case of any such proceeding instituted against
it (but not instituted by it), shall remain undismissed or unstayed for a period of 30 days; or
such Person shall take any action to authorize any of the actions set forth above.

     “BOE” means one barrel of oil equivalent, calculated by converting natural gas to oil
equivalent barrels at a ratio of six thousand cubic feet of natural gas to one stock tank barrel,
or 42 U.S. gallons liquid volume, of oil.

     “Business” means the business of the Partnership Group.

     “Confidential Information” means non-public information about the disclosing Party’s or any of
its Affiliates’ business or activities that is proprietary and confidential, which shall include,
without limitation, all business, financial, technical and other information, including software
(source and object code) and programming code, of a Party or its Affiliates marked or designated
“confidential” or “proprietary” or by its nature or the circumstances surrounding its disclosure it
should reasonably be regarded as confidential. Confidential Information includes not only written
or other tangible information, but also information transferred orally, visually, electronically or
by any other means. Confidential Information does not include information that (i) is in or enters
the public domain without breach of this Agreement, or (ii) the receiving Party lawfully receives
from a third party without restriction on disclosure and to the receiving Party’s knowledge without
breach of a nondisclosure obligation.

     “COPAS” means the Council of Petroleum Accountants Societies.

     “Damages” is defined in Section 9.1.

     “Default Rate” means an interest rate (which shall in no event be higher than the rate
permitted by applicable law) equal to the prime interest rate of the Operating Company’s principal
lender.

     “Effective Date” is defined in the introductory paragraph.

     “Encore Acquisition Company” means Encore Acquisition Company, a Delaware corporation.

     “Encore Group” means Encore Acquisition Company and is Affiliates (other than any member of
the Partnership Group).

     “Encore Operating Party” is defined in Section 9.1.

     “Environmental Law” means current local, county, state, federal, and/or foreign law (including
common law), statute, code, ordinance, rule, order, judgment, decree, regulation or other legal
obligation relating to the protection of health, safety or the environment or natural

2

 

resources, including, without limitation, the Comprehensive Environmental Response Compensation and Liability
Act (42 U.S.C. section 9601 et seq.), as amended, the Resource Conservation and Recovery Act (42
U.S.C. section 6901 et seq.), as amended, the Federal Water Pollution Control Act (33 U.S.C.
section 1251 et seq.), as amended, the Clean Air Act (42 U.S.C. section 7401 et seq.), as amended,
the Toxic Substances Control Act (15 U.S.C. section 2601 et seq.), as amended, the Occupational
Safety and Health Act (29 U.S.C. section 651 et seq.), as amended, the Safe Drinking Water Act (42
U.S.C. section 300(f) et seq.), as amended, analogous state, tribal or local laws, and any similar,
implementing or successor law, and any amendment, rule, regulation, or directive issued thereunder,
including any determination by, or interpretation of any of the foregoing by any Governmental
Authority that has the force of law.

     “Force Majeure” means any cause beyond the reasonable control of a Party, including the
following causes (unless they are within such Party’s reasonable control): acts of God, strikes,
lockouts, acts of the public enemy, wars or warlike action (whether actual or impending), arrests
and other restraints of government (civil or military), blockades, embargoes, insurrections, riots,
epidemics, landslides, lightning, earthquakes, fires, sabotage, tornadoes, named tropical storms
and hurricanes, floods, civil disturbances, terrorism, mechanical breakdown of machinery or
equipment, explosions, confiscation or seizure by any government or other public authority and any
order of any court of competent jurisdiction, regulatory agency or governmental body having
jurisdiction.

     “G&A Services” means those general and administrative services necessary or useful for the
conduct of the business of the Partnership Group, including, but not limited to, accounting,
corporate development, finance, land, marketing, legal and engineering.

     “Governmental Approval” means any material consent, authorization, certificate, permit,
right-of-way grant or approval of any Governmental Authority that is necessary for the
construction, ownership and operation of the Business in accordance with applicable Laws.

     “Governmental Authority” means any court or tribunal in any jurisdiction or any federal,
state, tribal, municipal or local government or other governmental body, agency, authority,
department, commission, board, bureau, instrumentality, arbitrator or arbitral body or any
quasi-governmental or private body lawfully exercising any regulatory or taxing authority.

     “Laws” means any applicable statute, Environmental Law, common law, rule, regulation,
judgment, order, ordinance, writ, injunction or decree issued or promulgated by any Governmental
Authority.

     “Parties” is defined in the introductory paragraph.

     “Partnership” is defined in the introductory paragraph.

     “Partnership Agreement” means the Second Amended and Restated Agreement of Limited Partnership
of the Partnership, as may be amended or restated from time to time.

     “Partnership Group” means the General Partner, the Partnership, the Operating Company and all
of their respective Subsidiaries.

3

 

     “Partnership Group Party” is defined in Section 9.1.

     “Payment Amount” is defined in Section 4.1.

     “Person” means an individual or a corporation, limited liability company, partnership, joint
venture, trust, unincorporated organization, association, government agency or political
subdivision thereof or other entity.

     “Services” is defined in Section 2.2.

     “Subsidiary” means, with respect to any Person, (a) a corporation of which more than 50% of
the voting power of shares entitled (without regard to the occurrence of any contingency) to vote
in the election of directors or other governing body of such corporation is owned, directly or
indirectly, at the date of determination, by such Person, by one or more Subsidiaries of such
Person or a combination thereof, (b) a partnership (whether general or limited) in which such
Person or a Subsidiary of such Person is, at the date of determination, a general or limited
partner of such partnership, but only if more than 50% of the partnership interests of such
partnership (considering all of the partnership interests of the partnership as a single class) is
owned, directly or indirectly, at the date of determination, by such Person, by one or more
Subsidiaries of such Person, or a combination thereof, or (c) any other Person (other than a
corporation or a partnership) in which such Person, one or more Subsidiaries of such Person, or a
combination thereof, directly or indirectly, at the date of determination, has (i) at least a
majority ownership interest or (ii) the power to elect or direct the election of a majority of the
directors or other governing body of such Person.

     Other terms defined herein have the meanings so given them.

     Section 1.2 Construction.

     Unless the context requires otherwise: (a) any pronoun used in this Agreement shall include
the corresponding masculine, feminine or neuter forms, and the singular form of nouns, pronouns and
verbs shall include the plural and vice versa; (b) references to Articles and Sections refer to
Articles and Sections of this Agreement; (c) references to Exhibits refer to the Exhibits attached
to this Agreement, each of which is made a part hereof for all purposes; (d) the terms “include”,
“includes”, “including” and words of like import shall be deemed to be followed by the words
“without limitation”; (e) the terms “hereof,” “herein” and “hereunder” refer to this Agreement as a
whole and not to any particular provision of this Agreement; and (f) references to money refer to
legal currency of the United States of America. The table of contents and headings contained in
this Agreement are for reference purposes only, and shall not affect in any way the meaning or
interpretation of this Agreement.

ARTICLE II

RETENTION OF ENCORE OPERATING; SCOPE OF SERVICES

     Section 2.1 Retention of Encore Operating. The Partnership hereby engages Encore Operating to perform the Services, as directed by the
General Partner, and to provide all personnel and any facilities, goods and equipment not otherwise
provided by the Partnership

4

 

Group necessary to perform the Services. Encore Operating hereby
accepts such engagement and agrees to perform the Services requested by the General Partner and to
provide any personnel, facilities, goods and equipment not otherwise provided by the Partnership
Group, and to provide all employees as may be reasonable and necessary to perform the Services.

     Section 2.2 Scope of Services. The “Services” shall consist of such services the General Partner determines may be reasonable
and necessary to operate the Business, including, without limitation, any G&A Services and those
services described on Schedule I hereto. Encore Operating hereby covenants and agrees that the
Services will be performed in accordance with (i) applicable material Governmental Approvals and
Laws and (ii) industry standards.

     Section 2.3 Exclusion of Services. The General Partner may temporarily or permanently exclude any particular service from the scope
of the Services upon 90 days’ notice to Encore Operating.

     Section 2.4 Performance of Services by Affiliates and Third Parties. The Parties hereby agree that in discharging its obligations hereunder, Encore Operating may
engage any of its Affiliates or any qualified third party to perform the Services (or any part of
the Services) on its behalf and that the performance of the Services (or any part of the Services)
by any such Affiliate or third party shall be treated as if Encore Operating performed such
Services itself. Notwithstanding the foregoing, nothing contained herein shall relieve Encore
Operating of its obligations hereunder.

     Section 2.5 Intellectual Property.

     (a) Any (i) inventions, whether patentable or not, developed or invented, or (ii)
copyrightable material (and the intangible rights of copyright therein) developed, by Encore
Operating, its Affiliates or its or their employees in connection with the performance of
the Services shall be the property of Encore Operating; provided, however, that the
Partnership Group shall be granted an irrevocable, royalty-free, non-exclusive and
non-transferable right and license to use such inventions or material; and further provided,
however, that the Partnership Group shall only be granted such a right and license to the
extent such grant does not conflict with, or result in a breach, default,
or violation of a right or license to use such inventions or material granted to Encore
Operating by any Person other than an Affiliate of Encore Operating. Notwithstanding the
foregoing, Encore Operating will use all commercially reasonable efforts to grant such right
and license to the Partnership Group.

     (b) The General Partner, the Partnership and the Operating Company hereby grant to
Encore Operating and its Affiliates an irrevocable, royalty-free, non-exclusive and
non-transferable right and license to use, during the term of this Agreement, any
intellectual property provided by the Partnership Group to Encore Operating or its
Affiliates, but only to the extent such use is necessary for the performance of the
Services. Encore Operating agrees that it and its Affiliates will utilize such intellectual
property solely in connection with the performance of the Services.

5

 

     Section 2.6 Appointment of Independent Accounting Firm and Independent Petroleum Engineer.
Notwithstanding anything to the contrary in this Agreement, the Parties hereby acknowledge and
agree that the General Partner shall have the exclusive authority to appoint an independent
registered public accounting firm to audit the financial statements of the Partnership and an
independent petroleum engineer to provide reports to the Partnership relating to estimates of
proved reserves for Securities and Exchange Commission and other reporting purposes.

ARTICLE III

BOOKS, RECORDS AND REPORTING

     Section 3.1 Books and Records. Encore Operating shall maintain accurate books and records regarding the performance of the
Services and its calculation of the Payment Amount, and shall maintain such books and records for
the period required by applicable accounting practices or Law.

     Section 3.2 Audits. The Partnership shall have the right, upon reasonable notice, and at all reasonable times during
usual business hours, to audit, examine and make copies of the books and records referred to in
Section 3.1. Such right may be exercised through any agent or employee of the Partnership Group
designated in writing by it or by an independent public accountant, engineer, attorney or other
agent so designated. The Partnership shall bear all costs and expenses incurred in any inspection,
examination or audit. Encore Operating shall review and respond in a timely manner to any claims
or inquiries made by the Partnership regarding matters revealed by any such inspection, examination
or audit.

     Section 3.3 Reports. Encore Operating shall prepare and deliver to the Partnership any reports provided for in this
Agreement and such other reports as the Partnership may reasonably request from time to time
regarding the performance of the Services.

ARTICLE IV

PAYMENT AMOUNT

Section 4.1 Payment Amount.

     (a) The Partnership shall on a quarterly basis (i) pay Encore Operating a fixed fee of
$1.75 per BOE of the Partnership Group’s total net oil and gas production for the then
completed quarter (the “Administrative Fee”) and (ii) reimburse Encore Operating for all
third-party expenses that Encore Operating incurs on behalf of the Partnership Group
(collectively with the Administrative Fee, the “Payment Amount”). In addition to the
Payment Amount, Encore Operating shall be entitled to retain any COPAS overhead charges
associated with drilling and operating wells that would otherwise be paid by third parties
to the operator of a well. For the avoidance of doubt,
the Partnership will pay all expenses that are directly chargeable to wells
under their respective joint operating agreements.

6

 

     (b) The Administrative Fee shall increase in the following circumstances:

     (i) Beginning on the first day of April in each year beginning with April 1,
2008, the Administrative Fee shall increase by an amount equal to the product of the
then-current Administrative Fee multiplied by COPAS Wage Index Adjustment for the
current year.

     (ii) If the Partnership or any other member of the Partnership Group acquires
additional assets, then Encore Operating may propose a revised Administrative Fee
that covers the provision of Services for such additional assets. If the General
Partner, on behalf of the Partnership Group and with the concurrence of the
conflicts committee of the board of directors of the General Partner, agrees to such
revised Administrative Fee, Encore Operating shall provide Services for the
additional assets pursuant to the terms set forth herein.

     (iii) If the Partnership and Encore Operating otherwise agree to increase the
Administrative Fee; provided, however, that any such increase shall be approved by
the board of directors of the General Partner with the concurrence of the conflicts
committee of such board.

     Section 4.2 Payment of Payment Amount. Encore Operating shall invoice the Partnership within 25 days after the close of each quarter
for the estimated Payment Amount, plus or minus any adjustment necessary to correct prior estimated
billings to actual billings. Subject to Section 4.3, all invoices shall be due and payable, in
immediately available funds, within thirty days after receipt of each invoice. Upon the request of
the Partnership, Encore Operating shall furnish a reasonable detail of the Services provided and
charges assessed during any quarter.

     Section 4.3 Disputed Charges. THE PARTNERSHIP MAY, WITHIN 120 DAYS AFTER RECEIPT OF A CHARGE FROM ENCORE OPERATING, TAKE
WRITTEN EXCEPTION TO SUCH CHARGE, ON THE GROUND THAT THE SAME WAS NOT A CORRECT CALCULATION OF THE
ADMINISTRATIVE FEE AND/OR A REASONABLE COST INCURRED BY ENCORE OPERATING OR ITS AFFILIATES IN
CONNECTION WITH THE SERVICES. THE PARTNERSHIP SHALL NEVERTHELESS PAY ENCORE OPERATING IN FULL WHEN
DUE THE FULL PAYMENT AMOUNT OWED TO ENCORE OPERATING. SUCH PAYMENT SHALL NOT BE DEEMED A WAIVER OF
THE RIGHT OF THE PARTNERSHIP TO RECOUP ANY CONTESTED PORTION OF ANY AMOUNT SO PAID. HOWEVER, IF THE
AMOUNT AS TO WHICH SUCH WRITTEN EXCEPTION IS TAKEN, OR ANY PART THEREOF, IS ULTIMATELY DETERMINED
NOT TO BE A CORRECT CALCULATION OF THE ADMINISTRATIVE FEE AND/OR A REASONABLE COST INCURRED BY
ENCORE OPERATING OR ITS AFFILIATES IN CONNECTION WITH ITS PROVIDING THE SERVICES HEREUNDER, SUCH
AMOUNT OR PORTION THEREOF (AS THE CASE MAY BE) SHALL BE REFUNDED BY ENCORE OPERATING TO THE
PARTNERSHIP TOGETHER WITH INTEREST THEREON AT THE DEFAULT RATE DURING THE PERIOD FROM THE DATE OF
PAYMENT BY THE PARTNERSHIP TO THE DATE OF REFUND BY ENCORE OPERATING.

     Section 4.4 Set Off. In the event that Encore Operating owes the Partnership a sum certain in an uncontested amount
under any other agreement, then any such amounts may be

7

 

aggregated and the Partnership and Encore
Operating may discharge their obligations by netting those amounts against any amounts owed by the
Partnership to Encore Operating under this Agreement. If the Partnership or Encore Operating owes
the other party a greater aggregate amount, that Party may pay to the other Party the difference
between the amounts owed.

     Section 4.5 Encore Operating’s Employees. The obligations under Sections 4.1 and 4.2, to the extent they relate to Services provided by
employees of Encore Operating or its Affiliates, shall be limited to payment to Encore Operating
for expenses in connection with its or its Affiliates’ employees engaged in the provision of
Services hereunder, and the Partnership shall not be obligated to pay to Encore Operating’s or its
Affiliates’ employees directly any compensation, salaries, wages, bonuses, benefits, social
security taxes, workers’ compensation insurance, retirement and insurance benefits, training and
other such expenses; provided, however, that the Partnership may, at its option, compensate such
employees under one or more equity-based incentive compensation plans for the provision of Services
hereunder; and provided further, however, that if Encore Operating fails to pay any employee, with
the exception of employee claims for amounts owed that Encore Operating disputes in good faith,
within 30 days of the date such employee’s payment is due:

     (a) The Partnership may (i) pay such employee directly, (ii) employ such employee
directly, (iii) notify Encore Operating and begin to pay all employees providing
service to the Partnership directly, or (iv) notify Encore Operating that this
Agreement is terminated and employ all employees directly; and

     (b) Encore Operating shall reimburse the Partnership, as the case may be, the amount
the Partnership paid to Encore Operating for employee services that Encore Operating did not
pay to any such employee.

     Section 4.6 Approval of Expenses. Encore Operating acknowledges that all charges for Services assessed by Encore Operating and
included in the Payment Amount must be approved by the persons authorized to approve such Payment
Amount pursuant to the Partnership’s governance and delegation-of-authority process. Additionally,
Encore Operating acknowledges that the Audit Committee of the Board of Directors of the General
Partner, or if there is no Audit Committee, the entire Board of Directors of the General Partner,
may at any time review the Payment Amounts and the levels of Services and, as a result, may direct
the Partnership to decrease the level of Services or to dispute a prior invoice pursuant to Section
4.3. In addition to the information Encore Operating is obligated to provide pursuant to Section
4.2, Encore Operating shall provide such other information as reasonably necessary to determine the
veracity or appropriateness of any Payment Amount hereunder.

ARTICLE V

FORCE MAJEURE

     A Party’s obligation under this Agreement shall be excused when and to the extent its
performance of that obligation is prevented due to Force Majeure; provided, however, that a Party
shall not be excused by Force Majeure from any obligation to pay money. The Party that is prevented
from performing its obligation by reason of Force Majeure shall promptly notify the

8

 

other Parties
of that fact and shall exercise due diligence to end its inability to perform as promptly as
practicable. Notwithstanding the foregoing, a Party is not required to settle any strike, lockout
or other labor dispute in which it may be involved; provided, however, that, in the event of a
strike, lockout or other labor dispute affecting Encore Operating, Encore Operating shall use
reasonable efforts to continue to perform all obligations hereunder by utilizing its management
personnel and that of its Affiliates.

ARTICLE VI

ASSIGNMENTS AND SUBCONTRACTS

     Section 6.1 Assignments.

     (a) Without the prior consent of Encore Operating, none of the Partnership or the other
members or the Partnership Group may sell, assign, transfer or convey any of its rights, or
delegate any of its obligations, under this Agreement to any Person.

     (b) Without the prior consent of the Partnership, Encore Operating may not sell,
assign, transfer or convey any of its rights, or delegate any of its obligations, under this
Agreement to any Person, other than the delegation of performance of Services to an
Affiliate of Encore Operating or a qualified third party as permitted by Section 2.4 and the
sale, assignment, transfer or conveyance of its rights hereunder to any such Affiliate.

     Section 6.2 Other Requirements. Subject to the other provisions hereof:

     (a) All materials and workmanship used or provided in performing the Services shall be
in accordance with applicable specifications and standards.

     (b) Encore Operating shall exercise reasonable diligence to obtain the most favorable
terms or warranties available from vendors, suppliers and other third parties, and where
appropriate, Encore Operating shall assign such warranties to the Partnership.

     (c) In rendering the Services, Encore Operating shall not discriminate against any
employee or applicant for employment because of race, creed, color, religion, sex, national
origin, age or handicap, and shall comply with all applicable provisions of Executive Order
11246 of September 24, 1965, and any successor order thereto. Subject to the above, Encore
Operating shall, to the extent practicable, engage employees who reside in or whose
businesses are located in the local area or state where the Services are performed.

     (d) Encore Operating agrees to exercise reasonable diligence to ensure that, during the
term of this Agreement, it shall not employ unauthorized aliens as defined in the
Immigration Reform and Control Act of 1986, or any successor law.

9

 

ARTICLE VII

TERMINATION

     Section 7.1 Termination by the Partnership on behalf of the Partnership Group.

     (a) Upon the occurrence of any of the following events, the Partnership, on behalf of
the Partnership Group, may terminate this Agreement by giving written notice of such
termination to Encore Operating:

     (i) Encore Acquisition Company and its Affiliates cease to maintain a direct or
indirect controlling interest in the General Partner or Encore Operating; or

     (ii) Encore Operating’s failure to pay any employee within thirty (30) days of
the date such employee’s payment is due, subject to the limitations described in
Section 4.5.

Any termination under this Section 7.1(a) shall become effective immediately upon delivery
of the notice first described in this Section 7.1(a), or such later time (not to exceed the
first anniversary of the delivery of such notice) as may be specified by the Partnership.

     (b) In addition to its rights under Section 7.1(a), the Partnership may terminate this
Agreement at any time by giving notice of such termination to Encore Operating. Any
termination under this Section 7.1(b) shall become effective 90 days after delivery of such
notice, or such later time (not to exceed the first anniversary of the delivery of such
notice) as may be specified by the Partnership.

     (c) In the event that Encore Operating becomes Bankrupt or dissolves and commences
liquidation or winding-up, this Agreement shall automatically terminate without notice to
Encore Operating.

     Section 7.2 Termination by Encore Operating.

     (a) Encore Operating may terminate this Agreement by giving written notice of such
termination to the Partnership in the event that Encore Acquisition Company and its
Affiliates cease to maintain a direct or indirect controlling interest in the General
Partner or Encore Operating.

Any termination under this Section 7.2(a) shall become effective immediately upon delivery
of the notice first described in this Section 7.2(a).

     (b) In addition to its rights under Section 7.2(a), Encore Operating may terminate this
Agreement at any time by giving notice of such termination to the Partnership. Any
termination under this Section 7.2(b) shall become effective 90 days after delivery of such
notice, or such later time (not to exceed the first anniversary of the delivery of such
notice) as may be specified by Encore Operating.

     Section 7.3 Effect of Termination. If this Agreement is terminated in accordance with Section 7.1 or 7.2, all rights and
obligations under this Agreement shall cease except for (a) obligations that expressly survive
termination of this Agreement; (b) liabilities and obligations

10

 

that have accrued prior to such
termination, including the obligation to pay any amounts that have become due and payable prior to
such termination, and (c) the obligation to pay any portion of the Payment Amount that has accrued
prior to such termination, even if such portion has not become due and payable at that time.

ARTICLE VIII

CONFIDENTIAL INFORMATION

     Section 8.1 Nondisclosure. Each of Encore Operating and the Partnership Group agrees that (i) it will not disclose to any
third party or use any Confidential Information disclosed to it by the other except as expressly
permitted in this Agreement, and (ii) it will take all reasonable measures to maintain the
confidentiality of all Confidential Information of the other Party in its possession or control,
which will in no event be less than the measures it uses to maintain the confidentiality of its own
information of similar type and importance.

     Section 8.2 Permitted Disclosure. Notwithstanding the foregoing, each Party may disclose Confidential Information (i) to the
extent required by a court of competent jurisdiction or other governmental authority or otherwise
as required by law, including without limitation disclosure obligations imposed under the federal
securities laws, provided that such Party has given the other Party prior notice of such
requirement when legally permissible to permit the other Party to take such legal action to prevent
the disclosure as it deems reasonable, appropriate or necessary, or (ii) to its consultants, legal
counsel, Affiliates, accountants, banks and other financing sources and their advisors.

ARTICLE IX

LIMITATION OF LIABILITY; INDEMNIFICATION

     Section 9.1 Limitation of Encore Operating’s Liability. Neither Encore Operating nor any of its controlling persons, directors, officers, employees,
agents and permitted assigns (each, an “Encore Operating Party”) shall have any liability to the
Partnership Group for any losses, damages (including, but not limited to, special, indirect,
punitive and/or consequential damages), claims, injury, liability, cost or expense (“Damages”)
arising out of this Agreement, whether such Damages arise on account of the furnishing of Services
hereunder, the failure to furnish Services hereunder, or otherwise, and whether or not such Damages
were caused by the negligence of the Encore Operating Party, including the Encore Operating Party’s
sole negligence; provided, however, that the foregoing limitation shall not apply to Damages caused
by the Encore Operating Party’s gross negligence or willful, intentional misconduct.

     Section 9.2 Partnership’s Indemnity. The Partnership agrees to indemnify, defend and hold harmless each Encore Operating Party from
and against any and all Damages arising out of this Agreement, whether such Damages arise on
account of the furnishing of Services hereunder, the failure to furnish Services hereunder, or
otherwise, and whether or not such Damages were caused by the negligence of any Encore Operating
Party, including the Encore Operating Party’s sole negligence; provided, however, that the
foregoing limitation shall not apply to Damages caused by the Encore Operating Party’s gross
negligence or willful, intentional misconduct.

11

 

     Section 9.3 Limitation of Damages. If the Partnership Group suffers Damages arising out of this Agreement, which Damages were
caused by the gross negligence or willful, intentional misconduct of Encore Operating, Encore
Operating’s sole liability to the Partnership Group shall be to properly perform the Services in
question at no additional cost to the Partnership Group and to pay the Partnership Group for any
and all direct damages suffered by the Partnership Group. Notwithstanding anything to the contrary
contained herein or at Law and in equity, in no event shall Encore Operating be liable for
punitive, special, indirect, incidental or consequential damages (including, without limitation,
damages for loss of business profits, business interruption or any other loss) arising from or
relating to any claim made under this Agreement or regarding the provision of or the failure to
provide Services, even if Encore Operating had been advised or was aware of the possibility of such
damages.

     Section 9.4 Affiliate; Third Parties. If Encore Operating uses the personnel of its Affiliates or third parties to provide Services,
Encore Operating shall be responsible for the acts and omissions of such personnel and third
parties to the extent provided in this Agreement, and no Affiliate of Encore Operating or third
party shall have any liability to the Partnership Group on account of any Damages suffered by the
Partnership Group arising out of this Agreement, whether or not such Damages were caused by their
negligence and/or gross negligence, including their sole negligence and/or sole gross negligence,
or their willful, intentional misconduct.

ARTICLE X

DISPUTE RESOLUTION

     If the Parties are unable to resolve any dispute regarding the validity or terms of this
Agreement or its termination, service or performance issues, there is a material breach of this
Agreement that has not been corrected within thirty (30) days of receipt of notice of such breach
or any other dispute between the parties related to this Agreement, either party hereto may refer
the matter to an arbitrator selected in accordance with the rules of JAMS in Tarrant County, Texas
as the exclusive remedy for any such dispute, and in lieu of any court action, which is hereby
waived. The only exception shall be a claim by either Party for injunctive relief pending
arbitration.

ARTICLE XI

GENERAL PROVISIONS

     Section 11.1 Notices. All notices or other communications required or permitted under, or otherwise in connection
with, this Agreement must be in writing and must be given by (1) depositing same in the mail,
addressed to the Person to be notified, postpaid and registered or certified with return receipt
requested, (2) transmitting by national overnight courier, (3) delivery in person or (4) facsimile
to such Party. Notice given by mail, national overnight courier or personal delivery shall be
effective upon actual receipt. Notice given by facsimile shall be effective upon confirmation of a
successful transmission. All notices to be sent to a Party pursuant to this Agreement shall be
sent to or made at the address, in each case as follows:

12

 

if to the General Partner or the Partnership:

Encore Energy Partners GP LLC

777 Main Street, Suite 1400

Fort Worth, TX 76102

Attention: President

Fax: (817) 877-1655

if to the Operating Company:

Encore Energy Partners Operating LLC

777 Main Street, Suite 1400

Fort Worth, TX 76102

Attention: President

Fax: (817) 877-1655

if to Encore Operating:

EAP Operating, Inc., its general partner

777 Main Street, Suite 1400

Fort Worth, TX 76102

Attention: President

Fax: (817) 877-1655

     Section 11.2 Further Action. The Parties shall execute and deliver all documents, provide all information and take or refrain
from taking action as may be necessary or appropriate to achieve the purposes of this Agreement.

     Section 11.3 Binding Effect. This Agreement shall be binding upon and inure to the benefit of the Parties hereto and their
heirs, executors, administrators, successors, legal representatives and permitted assigns.

     Section 11.4 Integration. This Agreement constitutes the entire Agreement among the Parties hereto pertaining to the
subject matter hereof and supersedes all prior agreements and understandings pertaining thereto.

     Section 11.5 Creditors. None of the provisions of this Agreement shall be for the benefit of, or shall be enforceable
by, any creditor of the Partnership.

     Section 11.6 Waiver. No failure by any party to insist upon the strict performance of any covenant, duty, agreement
or condition of this Agreement or to exercise any right or remedy consequent upon a breach
thereof shall constitute waiver of any such breach of any other covenant, duty, agreement or
condition.

     Section 11.7 Counterparts. This Agreement may be executed in counterparts, all of which together shall constitute an
agreement binding on all the Parties hereto, notwithstanding that all such Parties are not
signatories to the original or the same counterpart. Each Party shall become bound by this
Agreement immediately upon affixing its signature hereto.

13

 

     Section 11.8 Applicable Law. This Agreement shall be construed in accordance with and governed by the laws of the State of
Texas, without regard to the principles of conflicts of law.

     Section 11.9 Invalidity of Provisions. If any provision of this Agreement is or becomes invalid, illegal or unenforceable in any
respect, the validity, legality and enforceability of the remaining provisions contained herein
shall not be affected thereby.

     Section 11.10 Amendment or Restatement. This Agreement may be amended or restated only by a written instrument executed by each of the
Parties; provided, however, that after the completion of the Partnership’s initial public offering
of common units representing limited partner interests, the Partnership may not, without the prior
approval of the conflicts committee of the board of directors of the General Partner or, if there
is no such committee, the independent members of such board of directors, agree to any amendment or
modification of this Agreement that the General Partner determines will adversely affect the
holders of such common units. The Parties hereto agree that, for purposes of this Section 11.10,
any material change in the nature, quantity or duration of the Services to be provided under this
Agreement shall constitute a modification of this Agreement.

     Section 11.11 Directly or Indirectly. Where any provision of this Agreement refers to action to be taken by any Party, or which such
Party is prohibited from taking, such provision shall be applicable whether such action is taken
directly or indirectly by such Party, including actions taken by or on behalf of any Affiliate of
such Party.

14

 

     IN WITNESS WHEREOF, the Parties have executed this Agreement on, and effective as of, the
Effective Date.

	 	 	 	 	 
	 	ENCORE ENERGY PARTNERS GP LLC

 	 
	 	By:  	 	 
	 	 	Name:  	 	 
	 	 	Title:  	 	 
	 
	 	ENCORE ENERGY PARTNERS LP

 	 
	 	By:  	Encore Energy Partners GP LLC, its General Partner
 	 
	 	 	 	 
	 	 	 	 
	 	By:  	
 	 
	 	 	Name:  	 	 
	 	 	Title:  	 	 
	 
	 	ENCORE ENERGY PARTNERS OPERATING LLC

 	 
	 	By:  	 	 
	 	 	Name:  	 	 
	 	 	Title:  	 	 
	 
	 	ENCORE OPERATING, L.P.

 	 
	 	By:  	EAP Operating, Inc., its General Partner
 	 
	 	 	 	 
	 	 	 	 
	 	By:  	
 	 
	 	 	Name:  	 	 
	 	 	Title:  	 	 
	 

15

 

SCHEDULE I

SERVICES PROVIDED BY ENCORE OPERATING

TO THE PARTNERSHIP GROUP

	1.	 	Accounting
	 
	2.	 	Information Technology
	 
	3.	 	Real Property
	 
	4.	 	Legal
	 
	5.	 	Securities and Exchange Commission Reporting
	 
	6.	 	Operations/Reservoir Engineering/Geology/Geophysics
	 
	7.	 	Administrative Services
	 
	8.	 	Financial Services
	 
	9.	 	Insurance Services
	 
	10.	 	Risk Management
	 
	11.	 	Corporate Development
	 
	12.	 	Commercial and Marketing
	 
	13.	 	Treasury
	 
	14.	 	Tax
	 
	15.	 	Audit
	 
	16.	 	Sarbanes-Oxley Compliance
	 
	17.	 	Investor Relations

I-1

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00126-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00126-of-00352.parquet"}]]