Document:

<Page>
                                                                    Exhibit 10.2

                                    AGREEMENT

                                     BETWEEN

                             LIDO CASINO RESORT, LLC

                                       AND

                             GGP LIMITED PARTNERSHIP

                           DATED: AS OF APRIL 12, 2004

<Page>

                                TABLE OF CONTENTS

<Table>
<Caption>

                                                                                             PAGE
                                                                                            ------
<S>                                                                                         <C>
ARTICLE 1 CERTAIN DEFINITIONS...................................................................2

ARTICLE 2 DESIGN OF MALL IMPROVEMENTS..........................................................10

ARTICLE 3 CONSTRUCTION OF MALL IMPROVEMENTS....................................................14

ARTICLE 4 DESIGN OF BUILD-OUT OF PHASE II MALL.................................................22

ARTICLE 5 CONSTRUCTION OF BUILD-OUT............................................................23

ARTICLE 6 ACCESS TO PHASE II LAND; RELATED MATTERS.............................................26

ARTICLE 7 TIMING FOR DESIGN AND CONSTRUCTION...................................................27

ARTICLE 8 AMENDED REA AND COREA................................................................29

ARTICLE 9 CONSULTATION; DISPUTE RESOLUTION.....................................................30

ARTICLE 10 MALL II BUYER CONDITIONS............................................................33

ARTICLE 11 DEVELOPER CONDITIONS................................................................35

ARTICLE 12 WAIVER OF CONDITIONS................................................................36

ARTICLE 13 CLOSING.............................................................................37

ARTICLE 14 CLOSING DELIVERIES; RELATED MATTERS.................................................37

ARTICLE 15 REPRESENTATIONS AND WARRANTIES  OF DEVELOPER; CERTAIN AGREEMENTS....................39

ARTICLE 16 REPRESENTATIONS AND WARRANTIES OF MALL II BUYER; CERTAIN AGREEMENTS.................46

ARTICLE 17 TRANSACTION EXPENSES; TITLE INSURANCE...............................................49

ARTICLE 18 DAMAGE OR DESTRUCTION; CONDEMNATION.................................................50

ARTICLE 19 REMOVAL OF TITLE DEFECTS............................................................51

ARTICLE 20 CLOSING AND OTHER PAYMENTS..........................................................52

ARTICLE 21 PRE-CLOSING REMEDIES................................................................56

ARTICLE 22 POST-CLOSING REMEDIES...............................................................58

</Table>

                                       ii

<Page>

<Table>
<S>                                                                                         <C>
ARTICLE 23 NOTICES.............................................................................58

ARTICLE 24 MISCELLANEOUS.......................................................................59

SCHEDULES AND EXHIBITS

Schedule "1"        -      Phase II Land
Schedule "2"        -      Leasehold Airspace
Schedule "3"        -      Phase IA Airspace
Schedule "4"        -      Continuing Service Contracts
Schedule "5"        -      Permitted Encumbrances
Schedule "6"        -      Consents and Exceptions to Representations of the Parties
Schedule "7"        -      Miscellaneous Closing Deliveries
Schedule "8"        -      Authorized Representatives; Notice Addresses
Schedule "9"        -      Construction Safety & Health Manual
Schedule "10"       -      Organizational Representations of Developer and Mall II Buyer
Schedule "11"       -      Definition of Substantial Completion
Schedule "12"       -      REA
Schedule "13"       -      Mall II Buyer Legal Rates
Schedule "14"       -      Tenant Handbook
Schedule "15"       -      Cost Sharing Allocations
Schedule "16"       -      Master Lease Agreement
Schedule "17"       -      Intentionally Omitted
Schedule "18"       -      Leases
Schedule "19"       -      Gaming Provisions for Leases
Schedule "20"       -      Work Continuation Agreement

Exhibit A           -      Standards Document, attaching Leasing Plans and Character Sketches
Exhibit B           -      Developer's Representation Certificate

</Table>

                                      iii

<Page>

                             INDEX OF DEFINED TERMS

<Table>
<Caption>

TERM                                                                                               SECTION
----                                                                                               -------
<S>                                                                                                <C>

Adjustment Payment....................................................................................20.2
Affiliate..............................................................................................1.1
Agreement..............................................................................................1.1
Amended REA............................................................................................8.1
amended................................................................................................1.2
amendment..............................................................................................1.2
Anticipated Completion Date............................................................................3.8
As-Built Floor Area....................................................................................2.3
Assignment............................................................................................14.1
at Developer's expense.................................................................................1.2
at Mall II Buyer's expense.............................................................................1.2
Authorized Representative..............................................................................1.1
Back-Of-House Areas..................................................................................Ex. A
Basket...............................................................................................15.12
Building...............................................................................................1.1
Build-Out..............................................................................................1.1
Build-Out Notice.......................................................................................3.7
Build-Out Work.........................................................................................1.1
Business Day...........................................................................................1.1
Buyer Delay............................................................................................1.1
Buyer Liquidated Damages Amount........................................................................7.1
Buyer's Proposed Final Checklist.......................................................................3.8
by hand.................................................................................................23
C of O.................................................................................................3.7
Cap..................................................................................................15.12
Cap Rate..............................................................................................20.2
Casino Shops..............................................................................WHEREAS Clause E
CE Warranty Work.......................................................................................3.4
Character Sketches...................................................................................Ex. A
Close-Out..............................................................................................3.4
Closing................................................................................................1.1
Closing Date..........................................................................................13.1
Closing Instruments....................................................................................1.1
Closing Payment.......................................................................................20.2
Common Area..........................................................................................Ex. A
Common Area Plans......................................................................................2.1
Common Elements........................................................................................1.1
Competitor.............................................................................................1.1
Condemnation..........................................................................................18.1
Construction Delay.....................................................................................1.1
Construction Safety & Health Manual....................................................................5.4
Consultant.............................................................................................1.1
Contractor Warranty....................................................................................3.4

</Table>

<Page>

<Table>
<S>                                                                                                <C>
Control................................................................................................1.1
COREA..................................................................................................8.2
CPI................................................................................................Sch. 15
CPI Adjustment.....................................................................................Sch. 15
CPI Increase.......................................................................................Sch. 15
day....................................................................................................1.2
Defective Work.........................................................................................3.4
delay..................................................................................................1.2
Demising Walls.........................................................................................2.2
Developer.........................................................................................Preamble
Developer Delay........................................................................................1.1
Developer Indemnitees..................................................................................5.2
Developer Liquidated Damages Amount...................................................................21.2
Developer's Architect..................................................................................1.1
Developer's Representation Certificate...............................................................15.12
Developer's Warranty...................................................................................3.4
Development............................................................................................1.1
Direct Costs...........................................................................................5.4
Disputing Parties......................................................................................9.2
Earn-Out Date.........................................................................................20.2
Earn-Out Payment......................................................................................20.2
Encumbrance............................................................................................1.1
Exceptions Notice......................................................................................3.8
Exclusive Mall Equipment...............................................................................1.1
Fee Mall Space.........................................................................................1.1
Fees and Costs.........................................................................................1.1
Field Changes..........................................................................................3.3
Final Construction Drawings and Specs..................................................................2.1
Final Date............................................................................................20.3
Final Demising Wall Plan...............................................................................2.2
First-Class............................................................................................1.1
Floor Area ............................................................................................1.1
Force Majeure..........................................................................................1.1
Gaming Authority.......................................................................................1.1
Gaming Licenses........................................................................................1.1
Government Authorities.................................................................................1.1
H/C I Owner............................................................................................1.1
H/C II Space...........................................................................................1.1
Hazardous Material(s)..................................................................................1.1
Impositions............................................................................................1.1
include................................................................................................1.2
including..............................................................................................1.2
Independent Expert.....................................................................................9.4
Initial Construction Drawings and Specs................................................................2.1
Initial Demising Wall Plan.............................................................................2.2
Initial Plans..........................................................................................2.1
</Table>

<Page>

<Table>
<S>                                                                                                <C>
Initial Market Disruption Date........................................................................20.2
Inspection Period......................................................................................3.8
Institutional Investor.................................................................................1.1
Interest Rate..........................................................................................1.1
Interim Liquidated Damages.............................................................................7.1
Interim Payment Date(s)...............................................................................20.2
Interim Substantial Completion Notices.................................................................3.8
knowledge............................................................................................15.10
Landlord Build-Out.....................................................................................1.1
Landlord Build-Out Work................................................................................1.1
law....................................................................................................1.2
laws...................................................................................................1.2
Lease..................................................................................................1.1
Leasing Plans........................................................................................Ex. A
Lease Damages..........................................................................................7.1
Leasehold.................................................................................WHEREAS Clause B
Leasehold Airspace........................................................................WHEREAS Clause B
Leasehold Mall Space...................................................................................1.1
Leasing Costs..........................................................................................1.1
Legal Proceeding.......................................................................................1.1
Legal Requirements.....................................................................................1.1
Major Event...........................................................................................18.1
Mall Equipment.........................................................................................1.1
Mall Opening Date......................................................................................7.2
Mall I Buyer...........................................................................................1.1
Mall I Call Price.....................................................................................21.2
Mall I LLC.............................................................................................1.1
Mall II Buyer.....................................................................................Preamble
Mall II Buyer Monthly Statement........................................................................3.2
Mall II Buyer Site Representative......................................................................9.1
Mall II LLC...............................................................................WHEREAS Clause D
Mall II Unit Warranty Work.............................................................................3.4
Mall II Unit...........................................................................................1.1
Mall Improvements......................................................................................1.1
Mall Indemnitees.......................................................................................3.5
Mall Space................................................................................WHEREAS Clause D
Market Disruption Event...............................................................................20.2
Master Lease Agreement....................................................................WHEREAS Clause E
McCarran Passengers...................................................................................20.2
Membership Interests......................................................................WHEREAS Clause G
month..................................................................................................1.2
Mortgage...............................................................................................1.1
No-Offset Clause.......................................................................................3.4
notice.................................................................................................1.2
Open for Business......................................................................................7.2
Opening Date...........................................................................................7.2
</Table>

<Page>

<Table>

<S>                                                                                                <C>
Outside Substantial Completion Date....................................................................7.1
Palazzo Casino Resort.....................................................................WHEREAS Clause C
party..................................................................................................1.2
Permitted Encumbrances.................................................................................1.1
Person.................................................................................................1.1
Phase I Hotel/Casino...................................................................................1.1
Phase I Mall...........................................................................................1.1
Phase I Mall Sale Agreement............................................................................1.1
Phase IA Airspace......................................................................................1.1
Phase IA Conference Center.............................................................................1.1
Phase II Automobile Parking Area.......................................................................1.1
Phase II Hotel/Casino..................................................................................1.1
Phase II Land.............................................................................WHEREAS Clause A
Phase II Mall Documents................................................................................1.1
Phase II Mall.............................................................................WHEREAS Clause E
Projected Fee Floor Area...............................................................................2.3
Proposed Final Checklist...............................................................................3.8
Projected Leasehold Floor Area.........................................................................2.3
Proposed Lease........................................................................................16.4
Proposed Tenant.......................................................................................16.4
Punch List Items...................................................................................Sch. 11
Punch List Work........................................................................................3.8
REA.......................................................................................WHEREAS Clause J
Recalculated Earn-Out.................................................................................20.3
recorded...............................................................................................1.2
Required Fee Floor Area................................................................................2.3
Required Leasehold Floor Area..........................................................................2.3
Required Mall Improvement Permits .....................................................................1.1
Retail and Restaurant Tenant Areas...................................................................Ex. A
Service Contract.......................................................................................1.1
Shared Mall Expenses...................................................................................8.2
Site Logistics Procedures..............................................................................5.4
SNDA..................................................................................................10.1
Standards Document.....................................................................................2.1
State..................................................................................................1.1
subject to the terms of this Agreement.................................................................1.2
Substantial Completion ............................................................................Sch. 12
Tenant.................................................................................................1.1
Tenant Build-Out.......................................................................................1.1
Tenant Build-Out Work..................................................................................1.1
Tenant Handbook........................................................................................5.1
Tenant Payments.......................................................................................16.3
Tenant Space...........................................................................................1.1
Title Defect..........................................................................................19.1
Title Insurance Commitment.............................................................................1.1
Title Insurer(s).......................................................................................1.1
</Table>

<Page>

<Table>

<S>                                                                                                <C>
Tsunami...............................................................................................10.1
Unit Owner.............................................................................................1.1
Use and Occupancy......................................................................................1.1
utilities..............................................................................................1.2
utility................................................................................................1.2
Venetian Casino Resort................................................................... WHEREAS Clause J

</Table>

<Page>

                                    AGREEMENT

        This AGREEMENT made as of April 12, 2004 by and between LIDO CASINO
RESORT, LLC, a Nevada limited liability company with an office at 3355 Las Vegas
Boulevard South, Room 1C, Las Vegas, NV 89109 ("DEVELOPER") and GGP Limited
Partnership, a Delaware limited partnership with an address at 110 North Wacker
Drive, Chicago, Illinois 60606 ("MALL II BUYER").

                             INTRODUCTORY STATEMENT

        A. WHEREAS, Developer is the owner in fee simple of that certain parcel
of land located in the County of Clark, State of Nevada as the same is more
particularly described on SCHEDULE "1" attached hereto and made a part hereof
(the "PHASE II LAND"); and

        B. WHEREAS, pursuant to that certain Commercial Lease dated as of March
1, 2004, by and between CAP II - Buccaneer, LLC, as landlord, and Developer, as
tenant, Developer is the holder of a leasehold interest (the "LEASEHOLD") in and
to that certain airspace described on SCHEDULE "2" attached hereto and made a
part hereof (the "LEASEHOLD AIRSPACE"); and

        C. WHEREAS, Developer intends to construct and operate a mixed use
development on the Phase II Land and within the Leasehold Airspace (such mixed
use development, including, without limitation, a hotel, casino, restaurant and
retail facility to be located on the Phase II Land and the Phase II Automobile
Parking Area, but excluding the Phase IA Airspace, the Phase IA Conference
Center and any other buildings and improvements located within the Phase IA
Airspace, the "PALAZZO CASINO Resort"); and

        D. WHEREAS, prior to Closing, Developer will assign and convey a portion
of the Palazzo Casino Resort consisting of a proposed mall with retail shops and
restaurants, together with those certain rights in the Common Elements as are
described herein, located in the airspace above the Phase II Land and/or
portions of the Leasehold Airspace (the "MALL SPACE") to an entity created for
the exclusive purpose of owning the mall to be constructed in the Mall Space and
being the lessee under the Master Lease Agreement ("MALL II LLC"); and

        E. WHEREAS, Developer intends to enter into that certain Casino Level
Restaurant/Retail Master Lease Agreement by and between Developer and Mall II
LLC (the "MASTER LEASE AGREEMENT") in substantially the form attached hereto as
SCHEDULE "16" whereby Developer will lease to Mall II LLC certain retail stores
in the Phase II Hotel/Casino (the "CASINO SHOPS" and, together with the Mall
Space, the "PHASE II MALL"); and

        F. WHEREAS, Developer will design and construct, for the consideration
described in Article 20 herein, the Mall Improvements, including the Common
Elements and the Demising Walls for Tenant Spaces located in the Phase II

<Page>

Mall simultaneously with the construction of the Palazzo Casino Resort pursuant
to the terms of this Agreement; and

        G. WHEREAS, upon the Closing Date, as defined herein, Developer will
sell and Mall II Buyer will purchase all of the limited liability company
interests in Mall II LLC (the "MEMBERSHIP INTERESTS") on the terms and
conditions set forth herein; and

        H. WHEREAS, Mall II Buyer and Developer will jointly implement, at
Developer's expense, the Build-Out of tenant spaces located in the Phase II
Mall, as described below; and

        I. WHEREAS, the Standards Document governing construction of the Mall
Improvements is attached hereto as EXHIBIT "A" and made a part hereof, the Phase
II Mall is depicted with greater particularity as the shaded areas on the
Leasing Plans attached to the Standards Document attached to this Agreement as
EXHIBIT "A;" and

        J. WHEREAS, that certain Second Amended and Restated Reciprocal Easement
Agreement to be entered into by and among H/C I Owner, Developer, Grand Canal
Shops II, LLC and Interface Group-Nevada, Inc. (the "REA") governs certain
aspects of the construction of the Palazzo Casino Resort and sets forth the
agreements of the parties thereto regarding the operation of the Palazzo Casino
Resort and that certain Venetian-themed complex containing a hotel and casino
and restaurant and retail space located adjacent to the Palazzo Casino Resort
(the "VENETIAN CASINO RESORT") and provides for the further amendment and/or
restatement of the REA to set forth additional agreements regarding the
admission of Mall II LLC as a party to the REA; and

        K. WHEREAS, The Palazzo Casino Resort and the Phase II Mall are each
intended to be First-Class projects of their type and to make optimal use of the
Phase II Land and the Leasehold Airspace, which is unique in its location on Las
Vegas Boulevard adjacent to the Venetian Casino Resort.

        NOW, THEREFORE, in consideration of the promises and obligations of
Developer and Mall II Buyer set forth in this Agreement, subject to the terms of
this Agreement and intending to be legally bound hereby, the parties agree as
follows:

                                   ARTICLE 1

                               CERTAIN DEFINITIONS

        1.1 The following words and phrases have the following meanings in this
Agreement:

        "Affiliate" when used with respect to a Person, shall mean a Person that
directly, or indirectly through one or more intermediaries, controls or is
controlled by, or is under common control with, the Person specified. The term
"control" (including the

                                       2
<Page>

terms controlling, controlled by and under common control with), as used herein,
means the possession, directly or indirectly, of the power to direct or cause
the direction of the management and policies of a Person, whether through (i)
the ownership of fifty percent (50%) or more of the voting rights with respect
to such Person, or (ii) ownership in such Person of thirty-three and one-third
percent (331/3%) or more of all equity, capital and profits interests.

        "Agreement" means this Agreement and the Exhibits and Schedules attached
hereto (or subsequently incorporated herein through amendments hereto), as the
same may be otherwise amended from time to time.

        "Authorized Representative" means an Authorized Representative of each
party identified on SCHEDULE "8" hereto.

        "Building" means the improvements to be constructed on the Phase II Land
and within the Leasehold Airspace, including the Phase II Hotel/Casino and the
Phase II Mall.

        "Build-Out" means Tenant Build-Out and Landlord Build-Out.

        "Build-Out Work" means the work of Developer or Tenants, as applicable,
necessary to accomplish the Build-Out.

        "Business Day" means any day other than Saturday or Sunday or a federal
holiday and/or the day upon which it is observed.

        "Buyer Delay" means any act or omission of Mall II Buyer, any tenant, or
their respective employees, agents, contractors or subcontractors in connection
with the Build-Out Work on the Phase II Land or otherwise, and/or any delay
constituting a Buyer Delay under this Agreement.

        "Closing" means the closing of the assignment of the Membership
Interests to Mall II Buyer and the other transactions occurring
contemporaneously therewith as contemplated under this Agreement.

        "Closing Instruments" means all instruments, agreements, and documents
required to be executed and/or delivered by Developer, Mall II LLC or Mall II
Buyer, respectively, at the Closing under this Agreement.

        "Common Elements" means the common areas and facilities of the Palazzo
Casino Resort as to which any, all, or some Unit Owners will have access,
interest, and/or rights of use pursuant to the Amended REA. The Common Elements
include the "Common Areas" and the "Back-of-House Area" described in the Initial
Plans.

        "Competitor" shall mean a Person that (i) owns or operates (or is an
Affiliate of an entity that owns or operates) a hotel located in Clark County,
Nevada or

                                       3
<Page>

Macau, a convention center located in Clark County, Nevada or Macau or any
casino and/or (ii) is a union pension fund.

        "Construction Delay" shall mean any delay caused by an act or omission
of either party, any tenant, or their respective employees, agents, contractors
or subcontractors in connection with the design and construction of the Mall
Improvements that is deemed a Construction Delay under this Agreement.

        "Consultant" means an architect, engineer, or other consultant, and/or
any of their respective subconsultants, engaged by a Person with respect to the
design and construction of the Mall Improvements and/or the Build-Out, or any
other portion of the Phase II Land or the Building, as applicable.

        "Control" shall have the meaning ascribed to it in the definition of
"Affiliate."

        "Developer Delay" means any act or omission of the Developer or its
employees, agents, contractors or subcontractors in connection with construction
of the Mall II Improvements on the Phase II Land and/or any other delay
constituting a Developer Delay under this Agreement.

        "Developer's Architect" means HKS Inc. of Nevada (or any successor
designated by Developer).

        "Development" means the portion of the Building (including the Mall
Improvements, the Phase II Hotel/Casino and the Build-Out) proposed to be
constructed by Developer on the Phase II Land and Leasehold Airspace.

        "Encumbrance" means a Mortgage, security agreement, security interest,
lien, levy, lease, pledge, hypothecation, charge, claim, license, judgment,
covenant, easement, and/or any other encumbrance or restriction of any and every
kind whatsoever.

        "Exclusive Mall Equipment" means those portions of the Mall Equipment
that will be used exclusively by or for the benefit of Mall II LLC and the Phase
II Mall and which shall be of a First-Class standard of a similar quality to
that equipment installed in the Phase I Mall.

        "Fee Mall Space" means that portion of the Phase II Mall built on the
Phase II Land, including the Casino Shops, to be assigned from Developer to Mall
II LLC.

        "Fees and Costs" means reasonable fees of attorneys, architects,
engineers, expert witnesses, consultants, and other Persons, and costs charged
by, or reimbursable to, the foregoing.

        "First-Class" means, as of any point in time, in compliance with the
highest standards or of the highest quality, or both, as applicable, in
accordance with

                                       4
<Page>

then-recognized standards in the industry in question; PROVIDED, however, that
wherever the foregoing shall be used in connection with the Phase II Mall, its
meaning shall be with reference to the highest standards or of the highest
quality, or both, as applicable, prevailing as of the date hereof on Las Vegas
Boulevard, Clark County, Nevada, and that wherever the foregoing shall be used
in connection with the Phase II Hotel/Casino, its meaning shall be with
reference to a standard no less than that of the Phase I Hotel/Casino as of the
date hereof.

        "Floor Area" means the area in square feet of a designated space
measured from the interior faces of the exterior walls. Calculation of Floor
Area includes those spaces occupied by columns, but excludes the spaces occupied
by stairwells, elevators and mechanical shafts.

        "Force Majeure" means any failure of or delay in the availability of any
public utility; any strikes, labor disputes, or unusual delays or shortages
encountered in transportation, fuel, material or labor supplies; casualties;
acts of God or the public enemy; governmental embargo restrictions, or actions
or inactions of any Government Authority (including any delays in issuing
approvals, building permits, certificates of occupancy or other similar permits
or certificates); injunctions; delays caused by the other party; or other acts
or occurrences beyond the reasonable control of a party (provided that any of
the foregoing events or occurrences shall not be Force Majeure if caused by the
party claiming Force Majeure).

        "Gaming Authorities" means the Nevada Gaming Commission, the Nevada
State Gaming Control Board, the Clark County Liquor and Gaming Licensing Board
and any other agency or subdivision of the State of Nevada, or any other agency
or subdivision thereof, or of any other Government Authority regulating gaming.

        "Gaming Licenses" means every license, franchise or other authorization
to own, lease, operate or otherwise operate gaming activities at the Venetian
Casino Resort or the Palazzo Casino Resort, including all such licenses granted
under the Nevada Gaming Control Act, as codified in Chapter 463 of the Nevada
Revised Statutes, as amended from time to time, and the regulations of the
Nevada State Gaming Commission promulgated thereunder, as amended from time to
time, and other applicable federal, state, local or foreign rules.

        "Government Authority" means the United States; the State; Clark County;
any other municipal government authority; any other political subdivision of any
of the foregoing; and any agency, authority, department, court, commission or
other legal entity of any of the foregoing.

        "H/C I Owner" means the Venetian Casino Resort, LLC.

        "H/C II Space" means, collectively, (x) the Phase II Land and any
buildings and other improvements located thereon, less and except the Phase IA
Airspace, the Phase IA Conference Center and any improvements located within the

                                       5
<Page>

Phase IA Airspace and (y) the Leasehold Airspace and any buildings and other
improvements located therein.

        "Hazardous Material(s)" means materials, substances, fluids, chemicals,
gases, or other compounds the presence, use, storage, emission, drainage,
leakage, effusion, modification, or disposition of which is prohibited by law or
is subject by law to specific procedures, controls, or restrictions, or which
are otherwise deemed toxic, poisonous, or unsafe. However, "Hazardous Materials"
shall not include substances which are used in compliance with applicable laws
in the ordinary course of a business use. "Hazardous Materials" include, in any
event, asbestos, lead paint, and PCBs.

        "Impositions" means all real estate and personal property taxes, general
and special assessments, water and sewer charges, road maintenance and other
infrastructure charges, license fees and other fees and charges assessed or
imposed by Government Authorities or quasi-Government Authorities upon the Phase
II Mall.

        "Institutional Investor" means a savings bank, savings and loan
association, a commercial bank or trust company (whether acting individually, or
in any fiduciary capacity), an insurance company, an educational institution, a
corporate employees', or state, municipal or similar public employees' welfare
or other pension or retirement fund or system, an investment bank, a mutual fund
or a commercial finance company.

        "Interest Rate" means the rate at which Mall II Buyer can borrow funds
under the corporate credit line of General Growth Properties, Inc. as of the
Closing Date, Earn-Out Date, an Interim Payment Date or the Final Date, as
applicable.

        "Landlord Build-Out" means the installations, furnishing, finishes,
fixtures, equipment, fitting-out and other tenant improvement work to be
constructed by the landlord under any Lease in order to prepare the Tenant
Spaces for occupancy by Tenants, provided that, in all events, Landlord
Build-Out does not include any Tenant Build-Out.

        "Landlord Build-Out Work" means the work of Developer necessary to
accomplish the Landlord Build-Out.

        "Lease" means any lease, license, occupancy agreement or other agreement
(including any use or occupancy arrangements created pursuant to Section 365 of
the Bankruptcy Code or otherwise in connection with any bankruptcy or insolvency
proceeding in respect of any tenant or occupant) demising or otherwise
permitting the possession, occupancy, use or enjoyment of the Phase II Mall or
any part thereof (including, without limitation, any concession or kiosk space),
and every modification, supplement or extension thereof.

        "Leasehold Mall Space" means that portion of the Phase II Mall to be
built in the Leasehold Airspace.

                                       6
<Page>

        "Leasing Costs" shall mean, with respect to all Leases in the aggregate,
the sum of all leasing commissions payable by Mall II LLC, or Developer on
behalf of Mall II LLC, to third party brokers, the cost of all tenant
improvement allowances payable by or tenant improvement work to be performed by
Mall II LLC, or Developer on behalf of Mall II LLC, in connection with the
commencement of a Lease and as required under such Lease, legal fees payable by
Mall II LLC, or Developer on behalf of Mall II LLC, to outside attorneys or to
Mall II Buyer's in-house counsel at the rates set forth on SCHEDULE "13"
attached hereto and made a part hereof, and all other amounts paid or payable by
Mall II LLC, or Developer on behalf of Mall II LLC, to a Tenant or third party
in connection with the commencement of a Lease.

        "Legal Proceeding" means an action, litigation, arbitration,
administrative proceeding, and other legal or equitable proceeding of any kind.

        "Legal Requirements" mean all statutes, laws, ordinances, rules,
regulations, executive orders and requirements of all Government Authorities
which are applicable to the Phase II Mall or any part thereof or the use or
manner of use thereof, or to owners or occupants thereof in connection with such
ownership, occupancy or use.

        "Mall Equipment" means machinery, equipment, fixtures, and other
tangible personal property which do not constitute real property and which will
be installed in, affixed to, and/or constructed as part of, the Mall
Improvements.

        "Mall I Buyer" means the "Purchaser" under and as defined in the Phase I
Mall Sale Agreement.

        "Mall I LLC" means Grand Canal Shops II, LLC.

        "Mall II Unit" means the Phase II Mall excluding the Common Elements
contained therein.

        "Mall Improvements" means certain improvements relating to the Phase II
Mall portion of the Palazzo Casino Resort (and also certain Common Elements
and/or other items) to be designed and constructed by Developer, as described in
Articles 2 and 3 of this Agreement and the Initial Plans, as the same may be
modified pursuant to the terms of this Agreement.

        "Mortgage" means a mortgage or deed of trust.

        "Permitted Encumbrances" means the Encumbrances described in SCHEDULE
"5."

        "Person" means an individual person, a corporation, partnership, trust,
joint venture, limited liability company, proprietorship, estate, association,
land trust, other trust, Government Authority or other incorporated or
unincorporated enterprise, entity or organization of any kind.

                                       7
<Page>

        "Phase I Hotel/Casino" means the hotel/casino to be operated in the
Venetian Casino Resort.

        "Phase I Mall" shall have the meaning ascribed to it in the REA.

        "Phase I Mall Sale Agreement" means that certain Purchase and Sale
Agreement dated as of even date herewith by and among Grand Canal Shops Mall MM
Subsidiary, Inc., Grand Canal Shops Mall Subsidiary, LLC and Mall I Buyer.

        "Phase IA Airspace" means a portion of the airspace above the Phase II
Land, as more particularly described in SCHEDULE "3" attached hereto and made a
part hereof.

        "Phase IA Conference Center" means the approximately 150,000 square feet
of additional meeting and conference space located in the Phase IA Airspace.

        "Phase II Automobile Parking Area" means a new and separate parking
structure that Developer intends to construct on the Phase II Land for the use
by, among others, Developer and Mall II LLC.

        "Phase II Hotel/Casino" means the hotel/casino constructed and operated
by Developer in the H/C II Space.

        "Phase II Mall Documents" means the following: (a) all drawings, plans,
contracts, licenses, warranties and specifications for the Mall Improvements to
be delivered to Mall II LLC at the Closing, and all operating manuals for the
Exclusive Mall Equipment; and (b) Developer's books, records, and correspondence
pertaining to the Service Contracts assumed by Mall II LLC or to which Mall II
LLC will remain a party (if any) and the operation, maintenance and repair of
the Exclusive Mall Equipment.

        "Required Mall Improvement Permits" means all permits and approvals of
and from applicable Government Authorities which are necessary for the
construction and completion of the Mall Improvements and the delivery of same to
Mall II Buyer (specifically excluding, without limitation, temporary or
permanent certificates of occupancy for individual Tenant Spaces).

        "Service Contract" means any contract or agreement to which Developer or
Mall II LLC is a party for the furnishing of management, maintenance, repairs,
supplies, or other services exclusively to the Phase II Mall, and all amendments
thereof, which will have a term expiring after the Closing Date (and which
cannot be cancelled without penalty on not more than 30 days' prior notice).

        "State" means the State of Nevada.

        "Tenant" means the tenant, licensee, occupant or other user to which
rights are granted under a Lease.

                                       8
<Page>

        "Tenant Build-Out" means the installations, furnishing, finishes,
fixtures, equipment, fitting-out and other tenant improvement work to be
constructed by any Tenant as required or permitted under the Leases in order to
prepare the Tenant Spaces for occupancy by Tenants.

        "Tenant Build-Out Work" means the work of Tenants necessary to
accomplish the Tenant Build-Out.

        "Tenant Space" means the portions of the Phase II Mall to be demised to
and occupied by individual Tenants.

        "Title Insurance Commitment" means a commitment to issue an owner's
policy of title insurance insuring the fee simple title in the Fee Mall Space
and leasehold title to the Leasehold Mall Space and the Casino Shops in Title
Insurer's standard form.

        "Title Insurer(s)" means any title insurance company or companies
selected by Mall II Buyer to issue the Title Insurance Commitment.

        "Unit Owner" means any entity which is a party to the REA or the Amended
REA and such party's respective successors and assigns.

        "Use and Occupancy" means use and occupancy as described in this
Agreement of the Phase II Mall by Mall II LLC for Mall II Buyer's intended
purposes.

        1.2 Wherever used in this Agreement:

                (a)     the words "include" or "including" shall be construed as
incorporating, also, "but not limited to" or "without limitation;"

                (b) the word "day" means a calendar day unless otherwise
specified;

                (c) the phrase "at Developer's expense" shall mean at the sole
cost and expense of Developer, but the payments to be made to Developer pursuant
to Article 20 herein shall be unaffected by the use of such phrase;

                (d) the phrase "at Mall II Buyer's expense," shall mean at the
sole cost and expense of Mall II Buyer;

                (e) the word "party" means each signatory to this Agreement;

                (f) the word "law" (or "laws") means any law, rule, regulation,
order, statute, ordinance, resolution, regulation, code, decree, judgment,
injunction, mandate or other legally binding requirement of a Government
Authority applicable in the particular context;

                (g) the word "notice" shall mean notice in writing (whether or
not specifically so stated);

                                       9
<Page>

                (h) "month" means a calendar month unless otherwise specified;

                (i) the word "amended" means "amended, modified, extended,
renewed, changed, or otherwise revised"; and the word "amendment" means
"amendment, modification, extension, change, renewal, or other revision;"

                (j) the phrase "subject to the terms of this Agreement" means
"upon and subject to all terms, covenants, conditions and provisions of this
Agreement;"

                (k) the word "delay" means a delay or interference to a
particular schedule which (i) will require more than a minimal rearrangement of
(or delay in) other activities or commitments by the affected party; (ii) was
not caused by action or inaction of the affected party; and (iii) is the sole
cause of the rearrangement of (or delay in) other activities or commitments by
the affected party;

                (l) the word "recorded" means submitted to the Recorder's Office
of Clark County, Nevada; and

                (m) the words "utility" (or "utilities") means gas, water,
chilled water, sewer, electricity, steam, power, and other utilities of any
kind.

        1.3 For purposes of this Agreement and except as set forth in Section
15.10, a party shall be deemed to have knowledge or notice of a matter if such
matter is actually known by, or if written notice disclosing such matter has
been given to an officer, director or individual general partner, member,
manager, or shareholder of such party or of a Person controlling such party.

        1.4 Other words and phrases are defined elsewhere in this Agreement and
listed in the Index of Defined Terms.

                                   ARTICLE 2

                           DESIGN OF MALL IMPROVEMENTS

        2.1 INITIAL PLANS AND CREATION OF CONSTRUCTION DRAWINGS.

                (a) THE STANDARDS DOCUMENT. EXHIBIT "A" attached hereto and made
a part hereof is that certain Palazzo Casino Resort, Retail Standards Document
which contains a description of certain details of the development and
construction of the Mall Improvements (the "STANDARDS DOCUMENT"). The Character
Sketches attached to the Standards Document are intended to illustrate the look
and feel of the Beverly Hills/Rodeo Drive theme only and shall not be binding as
to the particulars of the design or layout shown. Developer shall have the right
to change the Beverly Hills/Rodeo Drive theme upon prior notice to and written
consent by Mall II Buyer, which consent shall not be unreasonably withheld or
delayed.

                                       10
<Page>

                (b) COMMON AREA PLANS. Promptly upon execution of this
Agreement, Developer and Mall II Buyer shall negotiate expeditiously and in good
faith to develop a plan that is consistent with the Standards Document for the
location of the public common areas that will become part of the Common Elements
(the "COMMON AREA PLANS" and, together with the Standards Document, as the same
may be revised pursuant to this Agreement, the "INITIAL PLANS"). Developer and
Mall II Buyer shall agree upon a Common Area Plan no later than ninety (90) days
following the date of execution of this Agreement. In the event that Developer
and Mall II Buyer, despite good faith efforts, have not agreed upon a Common
Area Plan as of such date, then the same shall constitute a Construction Delay
(the duration of which shall be one (1) day for each day after said ninety (90)
day period that the parties shall have failed to agree on a Common Area Plan).

        (c) CONSTRUCTION DRAWINGS AND SPECS.

                (i) DEVELOPMENT OF CONSTRUCTION DRAWINGS AND SPECS. Developer
will proceed, in consultation with Mall II Buyer, with the development of
construction drawings and specifications for the Mall Improvements. To this end,
Developer shall give to Mall II Buyer, for review, the construction drawings and
specifications at 50%, 75% and 100% of completion (each of the foregoing, the
"INITIAL CONSTRUCTION DRAWINGS AND SPECS"). Within ten (10) Business Days after
the receipt by Mall II Buyer of each of the Initial Construction Drawings and
Specs, time being of the essence, Mall II Buyer will have the right to submit
comments to Developer and to object to any feature shown in the Initial
Construction Drawings and Specs that deviates from the Initial Plans. Developer
and Mall II Buyer will consult to resolve any issues, but Developer may proceed
with the development of the construction drawings and specifications
notwithstanding Mall II Buyer's objection, subject to Mall II Buyer's rights
under this Section 2.1(c) and Article 10. To the extent that any feature is not
in conformance with the Initial Plans, Developer shall correct such feature in
the Initial Construction Drawings and Specs at Developer's Expense. If any
feature shown in any Initial Construction Drawings and Specs is in accordance
with the Initial Plans and Mall II Buyer requests a change to such feature, such
request shall be considered a request for a change to the Initial Plans and
shall be subject to Developer's approval pursuant to Section 3.3(b) of this
Agreement. Developer will furnish interpretations, explanations and additional
information if and as requested by Mall II Buyer within the ten (10) Business
Day period provided for in this Section, but the same shall not have the effect
of extending said ten-Business Day period.

                (ii) MALL II BUYER APPROVAL OF CONSTRUCTION DRAWINGS AND SPECS.
Within ten (10) Business Days after the receipt by Mall II Buyer of the final
version of the Initial Construction Drawings and Specs (i.e., at 100%
completion), time being of the essence, Mall II Buyer shall approve such Initial
Construction Drawings and Specs or submit specific objections to any feature
shown in such final Initial Construction Drawings and Specs that deviates from
the Initial Plans. Developer and Mall II Buyer will consult, in good faith, to
resolve such objections. In the event such Initial Construction Drawings and
Specs shall deviate from the Initial Plans, Developer shall revise such Initial
Construction Drawings and Specs one or more times and resubmit the

                                       11
<Page>

same to Mall II Buyer for approval, which shall be given or denied, in each
case, within ten (10) Business Days, time being of the essence. At such time as
Mall II Buyer approves such Initial Construction Drawings and Specs as in
accordance with the Initial Plans (or waives any deviation), Mall II Buyer shall
deliver a written notice to Developer approving such Initial Construction
Drawings and Specs (as so approved and as the same may be modified pursuant to
the terms of this Agreement, the "FINAL CONSTRUCTION DRAWINGS AND SPECS"). If
Mall II Buyer shall withhold or delay (beyond the then-applicable ten (10)
Business Day period) its approval of any Initial Construction Drawings and Specs
for any reason, unless the same shall deviate from the Initial Plans, then the
same shall constitute a Construction Delay (the duration of which shall be one
(1) day for each day after said ten (10) Business Day period that the Final
Construction Drawings and Specs are not approved) for the purposes of this
Agreement. If any feature shown in any Final Construction Drawings and Specs is
in accordance with the Initial Plans and Mall II Buyer requests a change to such
feature, such request shall be considered a request for a change to the Initial
Plans and shall be subject to Developer's approval pursuant to Section 3.3(b) of
this Agreement. In the event Developer desires to amend the Final Construction
Drawings and Specs in any material respect, such amendment shall be subject to
Mall II Buyer's review and approval in accordance with this subsection
2.1(c)(ii), except that Mall II Buyer shall have five (5) Business Days to
respond to any request for amendment.

        2.2 ELEMENTS OF DESIGN OF THE MALL IMPROVEMENTS; DEMISING WALLS.

        (a) ELEMENTS OF THE STANDARDS DOCUMENT. The Standards Document
identifies the components of the Mall Improvements and set forth certain
locational, dimensional and design requirements pertaining to the Phase II Mall.
In particular, the Standards Document contains descriptions of (i) the
back-of-house area (for circulation of mall tenants and employees), (ii) the
publicly accessible Common Elements that will serve as access to the retail
spaces and the Phase II Hotel/Casino and (iii) the standards for construction of
certain elements of retail and restaurant Tenant Spaces.

        (b) REQUIRED ELEMENTS OF THE PHASE II HOTEL/CASINO. The drawings and
written specifications and requirements in the Initial Plans do not include
details for the Phase II Hotel/Casino or certain of the Common Elements located
outside the Phase II Mall. The Developer shall be obligated to design and
construct a First-Class hotel and casino with no less than 2,000 guest rooms on
the Phase II Land and in the Leasehold Airspace; provided, that the completion
of such hotel and casino shall not be a condition precedent to Closing, except
as expressly provided in this Agreement.

        (c) DEMISING WALLS. The Initial Plans do not set forth the location of
demising walls between the Tenant Spaces or between the Tenant Spaces and the
Common Elements of the Phase II Mall (the "DEMISING WALLS"), which have not yet
been finally determined. The location of the Demising Walls shall be determined
jointly by Mall II Buyer and Developer as the parties identify Tenants for the
retail and restaurant Tenant Spaces in two stages, described as follows:

                                       12
<Page>

        (i) Upon final determination of the Common Area Plans by the parties,
Mall II Buyer and Developer shall negotiate expeditiously and in good faith to
develop a plan for the location of the Demising Walls that is consistent with
the Initial Plans and/or the Final Construction Drawings and Specs, if the same
have been agreed upon, identifying whether each Tenant Space will be occupied by
a restaurant or retail tenant, showing the specifications and points of
connection with the Tenant Space of all utilities required for each such Tenant
Space and identifying the location of smoke walls (as the same may be modified
in accordance with this Agreement, the "INITIAL DEMISING WALL PLAN"). Mall II
Buyer and Developer shall agree upon an Initial Demising Wall Plan no later than
six (6) months after the date of execution of this Agreement. In the event that
Mall II Buyer and Developer, despite good faith efforts, have not agreed upon an
Initial Demising Wall Plan by such date, the same shall constitute a
Construction Delay (the duration of which shall be one (1) day for each day
after said six (6) month period that the parties shall have failed to agree on
an Initial Demising Wall Plan).

        (ii) Upon the final determination of the Initial Demising Wall Plan,
Mall II Buyer and Developer shall negotiate expeditiously and in good faith to
supplement the same to show the location, consistent with the Initial Plans, of
all Demising Walls (as the same may be modified in accordance with this
Agreement, the "FINAL DEMISING WALL PLAN"). Mall II Buyer and Developer shall
agree upon a Final Demising Wall Plan no later than one (1) year after the date
of execution of this Agreement. In the event that Mall II Buyer and Developer,
despite good faith efforts, have not agreed upon a Final Demising Wall Plan by
such date, the same shall constitute a Construction Delay (the duration of which
shall be one (1) day for each day after said one (1) year period that the
parties have failed to agree on a Final Demising Wall Plan).

        2.3 CALCULATION OF FLOOR AREA.

        (a) The Phase II Mall is intended to consist of 118,000 square feet of
Floor Area of Leasehold Mall Space (the "PROJECTED LEASEHOLD FLOOR AREA") and
279,018 square feet of Floor Area of Fee Mall Space (the "PROJECTED FEE FLOOR
AREA"). Mall II Buyer and Developer acknowledge and agree that the actual
as-built Floor Area of the Leasehold Mall Space and the Fee Mall Space may be
greater or less than the Projected Leasehold Floor Area and the Projected Fee
Floor Area, respectively. Developer may, subject to the following provisions of
this Section 2.3, deliver to Mall II LLC an actual as-built Floor Area of the
Leasehold Mall Space and/or the Fee Mall Space that varies from the Projected
Leasehold Floor Area and the Projected Fee Floor Area, provided that (x) (unless
reductions in Floor Area are necessary in order to comply with Legal
Requirements, to obtain Required Mall Improvement Permits or to make design
changes that are reasonably necessary to insure the efficient operation of the
Building, in which event the Required Leasehold Floor Area and the Required Fee
Floor Area shall be further reduced as so required) (i) the Floor Area of the
Leasehold Mall Space shall not be less than 95% of the Projected Leasehold Floor
Area (the "REQUIRED LEASEHOLD FLOOR AREA") and (ii) the Floor Area of the Fee
Mall Space shall not be less 95% of the Projected Fee Floor Area (the "REQUIRED
FEE FLOOR AREA") and (y) in no event shall (i) the as-built Floor Area of the
Leasehold Mall Space be greater than 105% of the

                                       13
<Page>

Projected Leasehold Floor Area or (ii) the as-built Floor Area of the Fee Mall
Space be greater than 105% of the Projected Fee Floor Area, without the prior
consent of Mall II Buyer, not to be unreasonably withheld or delayed.

        (b) As promptly as possible after Developer delivers to Mall II Buyer
the notice of the Anticipated Completion Date, Developer and Mall II Buyer shall
attempt to agree on the as-built square footage of the Floor Area included in
the Mall Improvements for each of the Leasehold Mall Space and the Fee Mall
Space (the "AS-BUILT FLOOR AREA"). If Developer and Mall II Buyer are unable to
agree on which portions of the Mall Improvements are As-Built Floor Area or any
calculation of As-Built Floor Area, Developer and Mall II Buyer shall engage an
Independent Expert to resolve such disputes pursuant to the provisions of
Article 9.

        2.4 CONSULTANTS. Developer and Mall II Buyer each shall engage its own
Consultants with respect to the design and construction of the Development and
the Build-Out. Developer's and Mall II Buyer's Consultants shall consult with
each other for purposes of coordinating filings with the relevant Government
Authorities and related matters. Developer shall endeavor to deliver all
contracts with the general contractor, if other than Developer, and primary
subcontractors to Mall II Buyer no later than five (5) Business Days prior to
execution of such contracts. The delivery of such contracts to Mall II Buyer
shall be for informational purposes only and Mall II Buyer's consent shall not
be required to any contracts.

                                   ARTICLE 3

                        CONSTRUCTION OF MALL IMPROVEMENTS

        3.1 CONSTRUCTION BY DEVELOPER.

        (a) At Developer's expense, Developer shall construct the Mall
Improvements substantially in accordance with the Final Construction Drawings
and Specs and this Agreement, subject to Section 3.3 of this Agreement.
Developer shall construct the improvements to the standard of a First-Class Mall
of a level of quality substantially similar to that of the "Grand Canal Shoppes
at the Venetian" as of the date hereof. Developer shall diligently pursue all
Required Mall Improvement Permits. Developer shall cause the Mall Improvements
to be constructed free from material fault or defect; of good quality; in a
workman-like manner and incorporating only new materials and equipment; by means
and methods complying with applicable Legal Requirements and insurance
requirements; and so as to operate properly and otherwise in accordance with the
requirements of the Final Construction Drawings and Specs.

        (b) At Developer's expense, Developer shall complete, repair, replace,
rebuild and/or correct promptly all Mall Improvement work which is incorrect,
defective, incomplete, omitted, or not otherwise in compliance with the Final
Construction Drawings and Specs, as the same may have been modified pursuant to
the provisions of Section 3.3 of this Agreement, which Developer discovers, or
of which

                                       14
<Page>

Mall II Buyer or Mall II LLC gives written notice to Developer, prior to
Substantial Completion.

        3.2 INSPECTION BY MALL II BUYER. Mall II Buyer shall have the right
during usual business hours, at Mall II Buyer's expense and upon reasonable
notice to Developer, (a) to inspect the construction work of the Mall
Improvements to ascertain that the performance of such work adheres to the Final
Construction Drawings and Specs, and (b) without limiting the foregoing, to
review shop drawings for the Mall Improvement work. In any event, during the
last week of each month (or on such other regularly-established monthly date as
Developer shall designate as the regular inspection date), Mall II Buyer and/or
its Consultants shall inspect the Mall Improvements construction work performed
since the prior inspection. Based on such observation, Mall II Buyer shall
furnish to Developer a statement, in a form to be agreed by the parties,
relating to Mall II Buyer's objections with respect to the construction work
(the "MALL II BUYER MONTHLY STATEMENT"). However, issuance of the Mall II Buyer
Monthly Statement will not be construed as Mall II Buyer's acceptance of work
which is defective, incomplete, or otherwise not in compliance with the Final
Construction Drawings and Specs, or as Mall II Buyer's waiver of any rights
under this Agreement, or as Mall II Buyer's release of Developer or any of
Developer's contractors or any surety from any warranty, guarantee, or
obligation provided under this Agreement or the Final Construction Drawings and
Specs or the applicable construction contract(s).

        3.3 CONSTRUCTION CHANGES.

        (a) Changes to the Mall Improvements (whether before or after
commencement of construction) made by Developer that are consistent with the
Final Construction Drawings and Specs (or the Initial Plans, if the Final
Construction Drawings and Specs have not been agreed to pursuant to the terms of
this Agreement) and the Initial Demising Wall Plan or Final Demising Wall Plan,
after the same have been agreed to, may be made without Mall II Buyer's
approval, subject to Section 2.3. Changes to the Mall Improvements requested by
Developer that are not consistent with the Final Construction Drawings and Specs
(or the Initial Plans, if the Final Construction Drawings and Specs have not
been agreed to pursuant to the terms of this Agreement) and changes to the
Initial Demising Wall Plan, the Final Demising Wall Plan or the Common Area
Plan, after the same have been agreed to by Developer and Mall II Buyer, shall
be subject to Mall II Buyer's approval, which shall not be unreasonably withheld
or delayed if such change will not result in a failure of Developer to deliver
the Required Leasehold Floor Area or the Required Fee Floor Area.

        (b) Changes in the Final Construction Drawings and Specs (or the
Standards Document, if the Final Construction Drawings and Specs have not been
agreed to pursuant to the terms of this Agreement), the Mall Improvements, the
Initial Demising Wall Plan, the Final Demising Wall Plan and the Common Area
Plan, after the same have been agreed to by Developer and Mall II Buyer, that
are requested by Mall II Buyer shall be subject to Developer's approval, which
shall not be unreasonably withheld or delayed if such change (i) will not
require more than DE MINIMIS changes to the Building other than the Mall II
Unit, (ii) will not cause, in Developer's reasonable

                                       15
<Page>

judgment, a material delay in the completion of the Development, (iii) will not
adversely effect the Phase II Hotel/Casino and (iv) will not increase by more
than a DE MINIMIS amount the cost of constructing the Building and/or the Mall
II Unit unless Mall II Buyer agrees to pay such cost increase as and when
incurred.

        (c) If a change in the Initial Plans, the Final Construction Drawings
and Specs, the Initial Demising Wall Plan, the Final Demising Wall Plan, after
the same have been agreed to, or the Mall Improvements is required by law or in
order to obtain any Required Mall Improvement Permits, Developer shall advise
and promptly consult with Mall II Buyer as to the particular requirements and
the solution or solutions it is considering. If such change is required by any
Governmental Authority in order to issue a Required Mall Improvement Permit, or
if such change is consistent with the Standards Document, Developer shall not be
required to obtain Mall II Buyer's prior written approval for the proposed
manner of compliance; provided that, to the extent economically feasible,
Developer will make such change in the way that has the least impact on the
Initial Plans, the Final Construction Drawings and Specs, the Initial Demising
Wall Plan, the Final Demising Wall Plan and the Mall Improvements and the Final
Construction Drawings and Specs shall be modified accordingly. With respect to
any other such change, Developer and Mall II Buyer shall reasonably agree on
necessary and appropriate changes to be made to the Initial Plans, the Final
Construction Drawings and Specs, the Initial Demising Wall Plan, the Final
Demising Wall Plan and/or the Mall Improvements in order to comply with the
Legal Requirements or obtain the necessary permits, as applicable. In the event
that Developer proposes a method of compliance and Mall II Buyer requests that
Developer choose another method of compliance, Mall II Buyer shall pay to
Developer or reimburse Developer at Closing for any incremental costs (over the
cost of the method chosen by Developer) to effect such other method of
compliance. Developer shall pay any change costs associated with changes in the
Mall Improvements due to requirements of laws or inability to obtain necessary
permits, except as provided in the immediately preceding sentence, but shall not
pay associated fees of Mall II Buyer's Consultants (unless the legal compliance
requirement was a result of negligent acts or omissions of Developer or its
Consultants, as reasonably determined by the Independent Expert).

        (d) In this Agreement, "FIELD CHANGES" means minor and routine changes
necessitated by conditions in the field which are customarily resolved by
architects and construction managers and have no material cost or design
ramifications. Field Changes in the Mall Improvements and the Build-Out shall be
subject to approval by Developer's site representative (who shall act promptly)
in cooperation with Mall II Buyer's Site Representative (who shall act
promptly).

        3.4 CONSTRUCTION WARRANTIES.

        (a) This Section governs construction warranties or guaranties covering
or otherwise applicable to those portions of the Mall Improvements which will be
part of the Common Elements ("CE WARRANTY WORK") and those portions of the Mall
Improvements which will NOT be part of the Common Elements but will be the

                                       16
<Page>

responsibility of Mall II LLC and/or Mall II Buyer to maintain in accordance
with the Amended REA (collectively, "MALL II UNIT WARRANTY WORK").

        (b) As to both CE Warranty Work and Mall II Unit Warranty Work,
Developer shall include in its contracts with construction contractors
warranty/guaranty provisions customary for the type or category of work involved
(any such provision, a "CONTRACTOR WARRANTY") under which the respective
contractor will be required, at its expense, to repair, replace, and/or correct
work which is incorrect, defective, incomplete, or not otherwise in compliance
with the Final Construction Drawings and Specs ("DEFECTIVE WORK"). Developer
shall use commercially reasonable efforts to obtain the agreement of the
respective contractor (i) that Mall II LLC and Mall II Buyer shall be the
beneficiaries of, and may enforce directly, the contractor's Contractor Warranty
as to any Mall II Unit Warranty Work and/or CE Warranty Work located in the
Phase II Mall and (ii) that Mall II LLC and/or Mall II Buyer (and/or other Unit
Owners) may enforce their applicable warranties without set-off or defense by
reason of disputes between the Contractor and Developer (a "NO-OFFSET CLAUSE").
Any such Contractor Warranty for CE Warranty Work may also provide that other
Unit Owners are third party beneficiaries.

        (c) As to both CE Warranty Work and Mall II Unit Warranty Work, until
Developer has closed out the applicable contract and made final payment
(including release of retainage) to a contractor ("Close-Out"), Developer shall
use best efforts, at Developer's expense, to enforce the applicable Contractor
Warranty in accordance with its terms and conditions so as to cause such
contractor, at such contractor's expense, to repair, replace, and/or correct
Defective Work of which Developer becomes aware or of which either Mall II LLC
and/or Mall II Buyer gives notice to Developer. If there is any dispute
regarding whether any work performed is Defective Work, Developer and Mall II
Buyer shall submit the dispute for resolution to the Independent Expert, and the
determination of the Independent Expert shall be binding.

        (d) After Close-Out of a contract with a Contractor Warranty for CE
Warranty Work, Developer shall assign Developer's rights with respect to such
Contractor Warranty to the party responsible for maintaining such Common
Element, if not Developer.

        (e) After Close-Out of a contract with a Contractor Warranty for Mall II
Unit Warranty Work, Developer shall assign (on a non-exclusive basis)
Developer's rights with respect to such Contractor Warranty to Mall II LLC. If
Developer obtains and delivers to Mall II LLC a No-Offset Clause from a
particular contractor, Mall II LLC may thereafter enforce the Contractor
Warranty against such contractor, and Developer will have no further obligations
to do so. However, if Developer is unable to obtain a No-Offset Clause from a
particular contractor and the contractor raises on-going claims with Developer
as a defense in any claim by Mall II LLC for Defective Work against such
contractor, then Developer shall use Developer's best efforts, at Developer's
expense, to enforce the applicable Contractor Warranty in accordance with its
terms and conditions so as to cause such contractor, at such

                                       17
<Page>

contractor's expense, to repair, replace, and/or correct such Defective Work.
Moreover, if Developer has failed to obtain any Contractor Warranty that Mall II
LLC can enforce for the work of a particular contractor relating to any
particular Mall II Unit Warranty Work, Developer shall be responsible, at
Developer's expense, to repair, replace, and/or correct Defective Work in the
work of such contractor for a period of time equal to the length of a typical
warranty period for such work or one year from the date the item or work is
placed in service if there is no typical warranty period.

        (f) Developer will permit Mall II Buyer and its Consultants to review,
and will consult with them concerning, the text, terms, and conditions of
proposed Contractor Warranties for contractors who will perform the Mall
Improvement work which could become either CE Warranty Work or Mall II Unit
Warranty Work.

        (g) In the event that Developer does not engage a general contractor to
construct the Mall Improvements, at Closing, Developer shall deliver to Mall II
Buyer a warranty covering the construction of the Mall Improvements on terms
consistent with those typically offered by general contractors with respect to
similar projects (the "DEVELOPER'S WARRANTY"). In such event, the covenants with
respect to construction contracts and warranties thereunder set forth in Section
3.4(b), the first sentence of Section 3.4(c) and Sections 3.4(d) and 3.4(e)
shall be inapplicable and Developer shall retain the right to enforce all
Contractor Warranties.

        (h) The provisions of this Section 3.4 shall survive the Closing.

        3.5 DEVELOPER'S INDEMNIFICATION.

        (a) Developer agrees (at Developer's expense) to indemnify, defend and
hold harmless Mall II LLC, Mall II Buyer and their respective directors,
officers, stockholders, partners, members and employees (the foregoing
collectively the "MALL INDEMNITEES") from and against any loss, liability,
damage, cost, or expense (including Fees and Costs) which any of them may
suffer, or which may be asserted against any of them, in whole or in part by
reason of, or in connection with: (i) any bodily injury, sickness, disease or
death of or to any person or persons, or any damage to or destruction of
property, arising out of or resulting from acts or omissions of Developer, Mall
II LLC (to the extent taken or occurring prior to Closing) or Developer's
contractors or subcontractors in connection with the Mall Improvements or other
construction work relating to the Development, whether on the Phase II Land or
elsewhere; (ii) any failure by Developer, Mall II LLC (to the extent occurring
prior to Closing) or Developer's contractors or subcontractors to comply with
applicable Legal Requirements or insurance requirements; (iii) the use or misuse
by Developer, Mall II LLC (to the extent occurring prior to Closing) or
Developer's contractors or subcontractors of Hazardous Materials on the Phase II
Land; (iv) infringement of patent rights, licensing or royalty agreements, or
trade secrets by Developer, Mall II LLC (to the extent occurring prior to
Closing) or Developer's contractors or subcontractors in connection with the
Mall Improvements or other construction work relating to the Development,
whether on the Phase II Land or elsewhere; (v) any liens filed against the Phase
II Mall by any Person claiming by, through, or under Developer or Mall II LLC
(to

                                       18
<Page>

the extent relating to claims accruing before Closing); and/or (vi) any claims
under Developer's Warranty.

        (b) Developer shall defend any Legal Proceedings commenced against any
of the Mall Indemnitees concerning any matter covered by the foregoing
indemnification. Developer shall give Mall II Buyer copies of documents served
in any such Legal Proceeding and shall advise Mall II Buyer regularly as to the
status of the same. If Developer fails to defend diligently against any such
Legal Proceeding, or if Mall II Buyer reasonably believes that Developer's
interest in such Legal Proceeding is adverse to Mall II Buyer's interest
therein, Mall II Buyer shall have the right (but not the obligation), upon ten
(10) Business Day's prior written notice, to defend the same at Developer's
expense. Developer shall not settle any such Legal Proceeding without the
written consent of Mall II Buyer (unless such settlement shall release each Mall
Indemnitee against whom liability has been asserted from all liability with
respect to such Legal Proceeding without contribution from such Indemnitee). No
Mall Indemnitee may settle any such Legal Proceeding without the written consent
of Developer, which consent shall not be unreasonably withheld or delayed.

        (c) Mall II Buyer shall notify Developer promptly of every Legal
Proceeding or claim which may be covered by the indemnification in (a) above.
Developer's obligations under this Section 3.5 shall not be limited or defined
by the amount of insurance carried by Developer or by limitations on amount or
type of damages under worker's compensation acts or other laws relating to
employee benefits.

        (d) This Section shall not require indemnification of any Mall II Buyer
Indemnitee TO THE EXTENT of the negligence or willful misconduct of Mall II
Buyer, or of Mall II LLC after the transfer of the Membership Interests to Mall
II Buyer, any of their respective agents or affiliated Persons, or another Mall
Indemnitee.

        (e) The provisions of this Section 3.5 shall survive the Closing.

        3.6 INSURANCE COVERAGES. At Developer's expense, Developer shall include
Mall II LLC and Mall II Buyer as an additional insured on each policy of
liability insurance carried by Developer with respect to the Development with an
aggregate limit of not less than $25,000,000. Alternatively, the parties may
agree that Mall II LLC, Mall II Buyer and Developer may be included as insureds
under one or more liability policies covering the Mall Improvements and the
entire Development. Developer will carry, at Developer's expense, a policy of
builder's risk insurance for full replacement value (exclusive of footings and
foundations) on a completed value (reporting) basis and upon other commercially
standard terms and conditions covering construction of the Mall Improvements.

        3.7 COORDINATION OF BUILD-OUT. All Landlord Build-Out Work will be
performed and coordinated by Developer upon consultation with Mall II Buyer. The
parties recognize that it may be necessary or appropriate for Tenants and their
contractors and subcontractors to have access to the Phase II Mall before the
Closing to supervise and perform Tenant Build-Out Work, including any Tenant
Build-

                                       19
<Page>

Out Work which should be completed early in the process of constructing the Mall
Improvements (such as, for example, installation of wiring and conduit) to avoid
uncovering of completed Mall Improvement work after commencement of Tenant
Build-Out or otherwise to avoid re-doing of, or disruption to, the Mall
Improvement work. Mall II Buyer understands that the contractors and
subcontractors of any Tenant supervising and performing any Tenant Build-Out
Work will be subject to the direction and coordination of Developer and its
construction manager and Mall II Buyer and/or Developer shall so inform each
Tenant. Developer shall give written notice to Mall II Buyer (a "BUILD-OUT
NOTICE") when, in Developer's good faith judgment, the Mall Improvements or a
portion thereof have reached a stage of construction where it is safe and
appropriate for Tenants to have access to the Mall I Improvements or such
portion of the Mall Improvements for the purposes of supervising and performing
the Tenant Build-Out Work and such access will not interfere unreasonably with
construction of the Mall Improvements. At the Developer's election and based on
the progress of construction of the Building, the Build-Out Notice may be given
as one notice or a series of notices, each of which may give Tenants and their
respective contractors and subcontractors access to all or a portion of the Mall
II Improvements. After the giving of a Build-Out Notice, Tenant's contractors
shall have the right to enter the portions of the Phase II Mall covered by such
Build-Out Notice upon twenty-four (24) hours prior telephonic notice to
Developer for the purposes of performing the Tenant Build-Out Work. Developer
shall reasonably accommodate the scheduling of Tenant Build-Out Work (if any),
provided that the same will not interfere with the progress of the Mall
Improvement work. After the commencement of the Tenant Build-Out Work, Developer
may, from time to time, restrict Mall II Buyer's, any Tenant's or their
respective contractor's or subcontractor's access to the Mall Improvements in
order to complete other necessary construction work in the Mall Improvements and
on the Phase II Land. Developer shall use good faith efforts to keep such work
disruptions to a minimum and to schedule such disruptions so as to cause minimal
disruption to the completion of the Tenant Build-Out Work. Developer will obtain
at its expense permits with respect to Landlord Build-Out Work that it is
performing and Developer and Mall II Buyer shall jointly cause each Tenant to
obtain, all permits and approvals for construction of the Tenant Build-Out Work
that such Tenant is performing, other than the Required Mall Improvement Permits
(which Developer shall obtain at Developer's Expense). All Landlord Build-Out
Work shall be performed at the sole expense of Developer, and Mall II Buyer
shall not be responsible to pay any amount in regard of the Landlord Build-Out
Work. Entry by any Tenant or its contractors or subcontractors to perform Tenant
Build-Out Work shall not be deemed acceptance of the Mall Improvements by Mall
II Buyer or a waiver of Mall II Buyer's rights under this Agreement. Mall II
Buyer and Developer shall jointly cause Tenants and any contractors and
subcontractors, in performing the Tenant Build-Out Work, to take all reasonable
steps to minimize interference with construction of the Mall Improvements and
any other construction, shall comply with the Site Logistics Procedures and the
Tenant Handbook, and shall jointly cause Tenants to repair any damage to the
Mall Improvements (or other work in the Building) caused by Mall II Buyer, the
Tenants or any contractors and subcontractors in the performance of the Tenant
Build-Out Work. In no event shall the Tenant Build-Out Work performed by the
Tenants or any of their respective contractors or subcontractors involve any
modification

                                       20
<Page>

to the Mall II Improvements (without the prior consent of Developer) or
otherwise adversely affect Developer's ability to obtain a temporary certificate
of occupancy or a certificate of occupancy (a "C OF O") for any portion of the
Building. In the event that the performance of the Tenant Build-Out Work by
Tenant causes any delay in Developer obtaining a C of O for any portion of the
Building, such delay shall constitute a Construction Delay.

        3.8 SUBSTANTIAL COMPLETION; ACCEPTANCE PROCEDURE.

        (a) "SUBSTANTIAL COMPLETION" is defined in SCHEDULE "11" attached hereto
and made a part hereof.

        (b) In addition to the Interim Substantial Completion Notices described
in the following Section 3.8(c), Developer shall give Mall II Buyer at least
ninety (90) days' prior notice of Developer's good faith estimate of the date of
the anticipated occurrence of Substantial Completion of all of the Mall
Improvements (the "ANTICIPATED COMPLETION DATE"). When Developer determines that
Substantial Completion has occurred, Developer shall cause Developer's Architect
to prepare and submit to Mall II Buyer a list of remaining items to be completed
which it believes to be Punch List Items (as defined in SCHEDULE "11") (a
"PROPOSED FINAL CHECKLIST"). Within five (5) Business Days after Mall II Buyer's
receipt of the Proposed Final Checklist (the "INSPECTION PERIOD"), Mall II Buyer
shall conduct one or more inspection(s) of the Mall Improvements. If Mall II
Buyer believes that Substantial Completion has not yet occurred, Mall II Buyer
shall give Developer notice during the Inspection Period specifying why Mall II
Buyer believes that Substantial Completion has not yet occurred and setting
forth with sufficient specificity a list of work that Mall II Buyer believes is
still required to achieve Substantial Completion (an "EXCEPTIONS NOTICE"). In
the event an Exceptions Notice is delivered, subject to Section 3.8(c) below,
Developer shall cure or correct the conditions or matters specified in the
Exceptions Notice and shall cause Developer's Architect to deliver another
Proposed Final Checklist. If Mall II Buyer still believes that Substantial
Completion has not occurred, Mall II Buyer shall give another Exceptions Notice,
and the same procedure shall be repeated until Mall II Buyer agrees (or the
Independent Expert in good faith determines) that Substantial Completion has
occurred. If Mall II Buyer agrees (or the Independent Expert in good faith
determines) that Substantial Completion has occurred, Mall II Buyer shall give
Developer a notice (a "BUYER'S PROPOSED FINAL CHECKLIST") during the Inspection
Period specifying items not included on the Proposed Final Checklist which
remain to be completed or corrected. For purposes of determining Developer's
obligations with respect to items specified on any Buyer's Proposed Final
Checklist, the term "Buyer's Proposed Final Checklist" shall mean the list of
Punch List Items submitted by Mall II Buyer in accordance with this subsection
as amended following resolution as provided hereby by Developer and Mall II
Buyer of any dispute with respect thereto. Following delivery of the Proposed
Final Checklist to Mall II Buyer by Developer and/or the Buyer's Proposed Final
Checklist to Developer by Mall II Buyer, as the case may be, then, subject to
Force Majeure delays, Developer shall cause to be completed the items set forth
in the Proposed Final Checklist and Buyer's Proposed Final Checklist, if any
(collectively, "PUNCH LIST WORK") as soon as reasonably possible, and in all
events prior to the Opening Date, except to the extent

                                       21
<Page>

that minor items of Punch List Work that do not adversely effect the operation
of the Phase II Mall may be completed after the Opening Date. Developer's
indemnification in Section 3.5 and the insurance coverages set forth in Section
3.6 shall apply to all Punch List Work. Developer shall reimburse Mall II Buyer
or a Tenant, as applicable, for costs and expenses incurred by reason of any
damage caused by Developer or its contractors or subcontractors to the Tenant
Build-Out or any other property of Mall II Buyer or such Tenant.

        (c) Prior to giving the Anticipated Completion Notice described in
Section 3.8(b) above, Developer may give interim substantial completion notices
(the "INTERIM SUBSTANTIAL COMPLETION NOTICES") for portions of the Mall Space as
the same near Substantial Completion. The same procedure set forth in Section
3.8(b) of delivery of a Proposed Final Checklist, followed by an Exceptions
Notice and then the Buyer's Proposed Final Checklist shall apply following the
delivery of any Interim Substantial Completion Notices.

        (d) If Developer fails to commence the Punch List Work within thirty
(30) days after Substantial Completion of the entire Mall Improvements, subject
to Force Majeure, or if Developer does not thereafter diligently prosecute such
Punch List Work to completion, and if Mall II Buyer notifies Developer that
Developer is in default of its obligations to commence and diligently prosecute
the Punch List Work to completion and of Mall II Buyer's intention to undertake
the Punch List Work, then fifteen (15) days thereafter if the Punch List Work is
not completed or being diligently prosecuted to completion by Developer, Mall II
Buyer shall have the right (but not the obligation) to undertake the Punch List
Work itself (or through other Persons) at Developer's expense; and if and to the
extent that Mall II Buyer does so, Developer shall pay upon demand the
reasonable costs so incurred by Mall II Buyer.

        (e) Any dispute under this Section shall be submitted to the Independent
Expert for resolution. As to any matter so submitted, the time periods specified
in Sections 3.8(b) or 3.8(c) above shall be tolled until the date a decision is
reached or issued by the Independent Expert.

        (f) The provisions of this Section 3.8 shall survive the Closing.

                                   ARTICLE 4

                      DESIGN OF BUILD-OUT OF PHASE II MALL

        4.1 DESIGN OF BUILD-OUT. Mall II Buyer and Developer will jointly design
the Landlord Build-Out, and Mall II Buyer and Developer will jointly cause the
Tenants to design the Tenant Build-Out of the Tenant Spaces, so that the Phase
II Mall will be a First-Class mall with a Beverly Hills/Rodeo Drive theme and an
upscale neo-classical style as provided in the Initial Plans. Developer shall
have the right to deal directly with Tenants and the Tenant's' contractors to
the extent necessary for the coordination of the Build-Out design and
construction.

                                       22
<Page>

        4.2 BUILD-OUT DESIGN SUBMISSIONS FOR COORDINATION. Developer will
coordinate the Tenant Build-Out with the construction of the Mall Improvements
and the Landlord Build-Out and Mall II Buyer and Developer will jointly
supervise Tenants to ensure that the Tenant Build-Out is performed in accordance
with the Initial Plans, the Final Construction Drawings and Specs, the Initial
Demising Wall Plan, the Final Demising Wall Plan, this Agreement, the
Construction Safety & Health Manual, the Tenant Handbook, the Site Logistics
Procedures, the Work Continuation Agreement, the REA or the Amended REA.
Developer shall have the right to review and approve, in its reasonable
judgment, the consultant or contractors agreements for any Build-Out Work for
which it is required to pay. Mall II Buyer shall endeavor to deliver, or cause
Tenants to deliver, such contracts to Developer.

                                   ARTICLE 5

                            CONSTRUCTION OF BUILD-OUT

        5.1 CONSTRUCTION OF BUILD-OUT. Developer will undertake the construction
of the Landlord Build-Out, including agreement, upon consultation with Mall II
Buyer, on the terms and conditions of any contracts to construct the Landlord
Build-Out. Developer will ensure that the Landlord Build-Out is performed in
accordance with the Initial Plans, the Final Construction Drawings and Specs,
the Initial Demising Wall Plan, the Final Demising Wall Plan, this Agreement,
the Site Logistics Procedures, the Construction Safety & Health Manual, the
guidelines of the Tenant Handbook set forth in SCHEDULE "14" attached hereto and
made a part hereof, as the same may be modified to reflect the theme and layout
of the Phase II Mall and from time to time by Developer (the "TENANT HANDBOOK")
and the Work Continuation Agreement set forth in SCHEDULE "20" attached hereto
and made a part hereof. Developer will obtain at its expense with regard to any
Landlord Build-Out, and Developer and Mall II Buyer will cause Tenants to obtain
with respect to any Tenant Build-Out, all permits and approvals for construction
of the Tenant Build-Out other than the Required Mall Improvement Permits (which
Developer shall obtain at Developer's expense). The Landlord Build-Out shall be
constructed of good quality; in a workman-like manner and incorporating only new
materials and equipment; and by means and methods complying with applicable
Legal Requirements and insurance requirements. Developer shall commence the
Landlord Build-Out Work, and Mall II Buyer and Developer shall jointly cause
Tenants to commence the Tenant Build-Out Work no later than promptly after
delivery of the Build-Out Notice, subject to Force Majeure, Developer Delays,
Construction Delays and the Site Logistics Procedures. Developer shall be
responsible to pay all Leasing Costs in connection with the Landlord Build-Out.

        5.2 MALL II BUYER'S INDEMNIFICATION.

        (a) Mall II Buyer agrees (at Mall II Buyer's expense) to indemnify,
defend and hold harmless Developer and Mall II LLC (such indemnification of Mall
II LLC only prior to the assignment of the Membership Interests to Mall II
Buyer) and their respective directors, officers, stockholders, partners,
members, and

                                       23
<Page>

employees (the foregoing collectively the "DEVELOPER INDEMNITEES") from and
against loss, liability, damage, cost, or expense (including Fees and Costs)
which any of them may suffer, or which may be asserted against any of them, in
whole or in part by reason of, or in connection with: (i) any bodily injury,
sickness, disease or death of or to any person or persons, or any damage to or
destruction of property, arising out of or resulting from acts or omissions of
Mall II Buyer, Mall II LLC (to the extent taken or occurring after Closing), or
their respective contractors or subcontractors in connection with any act or
omission of any such party in respect of the Phase II Land or the Mall
Improvements; (ii) any failure by Mall II Buyer, Mall II LLC (to the extent
occurring after Closing), or their respective contractors or subcontractors to
comply with applicable Legal Requirements or insurance requirements; (iii) the
use or misuse by Mall II Buyer or Mall II LLC (to the extent occurring after
Closing) or their respective contractors or subcontractors of Hazardous
Materials on the Phase II Land or in the Leasehold Airspace; (iv) infringement
of patent rights, licensing or royalty agreements, or trade secrets by Mall II
Buyer or Mall II LLC (to the extent occurring after Closing), or their
respective contractors or subcontractors; and/or (v) any liens filed against the
Building and/or the Phase II Land or the Leasehold Airspace by any Person
claiming by, through, or under Mall II Buyer, Mall II LLC (to the extent
occurring after Closing) other than liens filed as a result of Developer's
failure to pay any Leasing Costs.

        (b) Mall II Buyer shall defend any Legal Proceedings commenced against
any of Developer Indemnitees concerning any matter covered by the foregoing
indemnification. Mall II Buyer shall give Developer copies of documents served
in any such Legal Proceeding and shall advise Developer regularly as to the
status of the same. If Mall II Buyer fails to defend diligently against any such
Legal Proceeding, or if Developer reasonably believes that Mall II Buyer's
interest in such Legal Proceeding is adverse to Developer's interest therein,
Developer shall have the right (but not the obligation), upon ten (10) Business
Day's prior written notice, to defend the same at Mall II Buyer's expense. Mall
II Buyer shall not settle any such Legal Proceeding without the written consent
of Developer (unless such settlement shall release each Developer Indemnitee
against whom liability has been asserted from all liability with respect to such
Legal Proceeding without contribution from such Indemnitee). No Developer
Indemnitee may settle any such Legal Proceeding without the written consent of
Mall II Buyer, which shall not be unreasonably withheld.

        (c) Developer shall notify Mall II Buyer promptly of every Legal
Proceeding or claim which may be covered by the indemnification in (a) above.
Mall II Buyer's obligations under this Section 5.2 shall not be limited or
defined by the amount of insurance carried by Mall II Buyer or by limitations on
the amount or type of damages under worker's compensation acts or other laws
relating to employee benefits.

        (d) This Section shall not require indemnification of any Developer
Indemnitee TO THE EXTENT of the negligence or willful misconduct of Developer,
Mall II LLC (prior to the transfer of the Membership Interests to Mall II
Buyer), any of their respective agents or another Developer Indemnitee.

        (e) The provisions of this Section 5.2 shall survive the Closing.

                                       24
<Page>

        5.3 INSURANCE COVERAGES. Mall II Buyer and Developer shall jointly cause
each Tenant with access to the Tenant Spaces to perform the Tenant Build-Out to
include Developer and Mall II LLC as additional insureds on each policy of
liability insurance carried by such Tenant, as applicable, with respect to the
Tenant Build-Out with a limit of not less than $10,000,000 with respect to any
Tenant. Mall II Buyer and Developer shall jointly cause each such Tenant to
furnish certificates evidencing all such insurance coverages to Developer before
such Tenant starts work in the Phase II Mall. Alternatively, the parties may
agree that Mall II Buyer, Mall II LLC and Developer may be included as insureds
under one or more liability policies covering the Build-Out and the entire
Building.

        5.4 SITE LOGISTICS PROCEDURES AND PLAN. Within a reasonable time before
Developer or a Tenant, as applicable, commences the Build-Out (so that Mall II
Buyer and Developer may plan and schedule site mobilization, logistics, and
materials deliveries), Developer shall promulgate procedures and a plan (the
"SITE LOGISTICS PROCEDURES") for mobilization, logistics, and access applicable
to all Persons performing construction work or services in the Building,
including work hours; delivery, handling and storage of materials; staging,
hoisting, use of elevators and loading docks, location of trailers; and other
such matters. All Persons performing work in the Building shall be required to
abide by the Construction Safety & Health Manual described on SCHEDULE "9"
attached hereto and made a part hereof, as the same may be modified by Developer
to reflect the Phase II Mall layout and other relevant facts (the "CONSTRUCTION
SAFETY & HEALTH MANUAL") and either Developer or H/C I Owner may, from time to
time, update and revise the Construction Safety & Health Manual in its
reasonable discretion. The parties acknowledge that staging, hoisting, etc. may
need to be integrated into the design and is crucial to construction sequencing.
The Site Logistics Procedures: (a) shall not discriminate against any Tenant in
such matters; (b) shall afford any Tenant performing Tenant Build-Out Work
regular but non-exclusive use of hoists and elevators for orderly and regular
access to the areas of the Building in which Tenant will perform any Tenant
Build-Out; (c) shall allow any Tenant orderly and regular access to those areas
of the Building outside the Phase II Mall which such Tenant must access to
supervise or perform the Tenant Build-Out; and (d) shall allow for sufficient
facilities, equipment and access to permit the orderly and continuous
prosecution and completion of the construction of the Tenant Build-Out by
Tenants and the contractors and subcontractors of Tenants during normal working
hours (and on an overtime basis if a Tenant elects to perform work on an
overtime basis and other construction work is permitted on an overtime basis).
The Site Logistics Procedures shall specify that Developer will provide hoists
and operating engineers to operate hoists and service elevators (but only so
long as such docks, hoists and elevators are available for use as of such date).
However, notwithstanding the foregoing, the Site Logistics Procedures may
provide that, starting on a date prior to the opening for business of any
portion of the Phase II Hotel/Casino, the access of Tenants (and their
respective contractors' and subcontractors') for supervision and construction of
the Tenant Build-Out shall be limited to the loading docks, hoists and service
elevators (but only so long as such docks, hoists and elevators are available
for use as of such date). Developer shall not discriminate against the Tenants
in applying the Site Logistics Procedures or otherwise in Developer's
administration of construction

                                       25
<Page>

work on, or access to or through, the Building. The Site Logistics Procedures
shall not impose any cost or charge for access to or through, or use of, any
facilities or areas of the Building EXCEPT FOR pass-through without markup of
actual labor, utility or equipment charges or other third-party costs
(collectively, "DIRECT COSTS") for use of facilities as to which labor or
special equipment are required and are specifically chargeable to or paid by
Developer (including overtime where applicable). The costs of the hoists and
service elevators shall not be included in Direct Costs, except to the extent
which a Tenant requests overtime service. If direct hourly rates do not apply,
Developer shall pay, unless the applicable Tenant shall be required to pay, 100%
of Direct Costs for equipment and facilities used exclusively by any Tenant and
an equitable portion of Direct Costs for equipment and facilities also used by
others as and to the extent actually used by any Tenant based on such Tenant's
percentage of use of special equipment and facilities (including overtime where
applicable). Developer shall provide dumpsters for use in connection with the
Tenant Build-Out. Mall II Buyer shall be responsible for cleaning their own work
area and removing their own trash to the provided dumpsters. Each Tenant shall
pay for the dumpster service as a part of the Direct Costs in accordance with
their Tenant Space's proportionate percentage of the total leasable Floor Area.

        5.5 INSPECTION BY DEVELOPER. Developer shall have the right (and Mall II
Buyer and Developer shall endeavor to include such a right in the Leases) during
usual business hours, at Developer's expense and upon reasonable notice to Mall
II Buyer or Tenants, to inspect the Tenant Build-Out Work to ascertain that the
performance of such work adheres to the Leases and design plans agreed to by
Mall II Buyer, Developer and Tenants.

                                   ARTICLE 6

                    ACCESS TO PHASE II LAND; RELATED MATTERS

        6.1 ACCESS. After the date hereof, Developer shall allow Mall II Buyer
and its Consultants, construction manager, contractors and representatives to
visit, inspect, and review the Phase II Land and the Building and matters
relating to the Phase II Land and the Building during working hours on Business
Days upon reasonable advance telephonic notice. Mall II Buyer's indemnification
in Section 5.2 and the insurance coverages set forth in Section 5.3 shall apply
to all inspections of the Phase II Land pursuant to this Article. In connection
with the joint leasing efforts described herein, Developer shall cooperate with
Mall II Buyer, including, without limitation, making available to Mall II Buyer
marketing materials with respect to the Phase II Hotel/Casino and (subject to
the provisions of this Section 6.1) permitting Mall II Buyer to conduct tours of
the Phase II Mall and the Phase II Hotel/Casino with prospective tenants.
Developer will also allow Mall II Buyer and its representatives (during working
hours on Business Days upon reasonable advance telephonic notice) to review and
copy information in Developer's possession (other than information which
Developer deems confidential) which may affect or relate to Mall II Buyer's
review or inspection of the design or construction of the Mall Improvements,
Mall II Buyer's participation in the design and construction of the Build-Out,
and/or Mall II Buyer's ownership and/or operation of the Phase II Mall after the
Closing or which Mall II Buyer may otherwise

                                       26
<Page>

reasonably request to confirm, verify or inquire into matters covered by this
Agreement, including the physical condition of the Phase II Land, plans,
surveys, title examinations, construction contracts, etc. Developer and
Developer's Consultants and representatives shall cooperate reasonably with Mall
II Buyer's Consultants and representatives in such matters. Any visits to, or
inspections at, the Phase II Land or the Building by Mall II Buyer or its
representatives shall not interfere with construction or other work in progress
and shall be subject to site safety concerns.

        6.2 INDEMNITY. Mall II Buyer agrees to indemnify Developer from and
against loss, cost, expense, damage, charge, claim or liability (including Fees
and Costs) which Developer may suffer, incur, or pay out by reason of the acts
or omissions of Mall II Buyer and its Consultants and representatives in making
any inspections of the Phase II Land and the Building pursuant to Section 6.1
(but not with respect to any condition at the Phase II Land or the Building
discovered by any inspections, examinations or tests). Mall II Buyer and its
Consultants shall have liability insurance in effect which covers any activities
on the Phase II Land or in the Building before the Closing in accordance with
Section 6.1. The provisions of this Section 6.2 shall survive the Closing.

                                   ARTICLE 7

                       TIMING FOR DESIGN AND CONSTRUCTION

        7.1 SUBSTANTIAL COMPLETION.

        (a) Developer shall give Mall II Buyer quarterly updates of the progress
of construction of the Mall Improvements and the Palazzo Casino Resort and
monthly updates for the six (6) months immediately preceding the date on which
Developer expects to achieve Substantial Completion. Developer shall achieve
Substantial Completion by the date that is the earlier of (i) thirty-six (36)
months after the date on which sufficient permits are received to allow
Developer to begin construction in compliance with Legal Requirements and (ii)
March 1, 2008, as the same may be extended due to Force Majeure, Construction
Delays or Buyer Delays (the "OUTSIDE SUBSTANTIAL COMPLETION DATE"). In the event
that, despite Developer's diligent efforts, Substantial Completion has not
occurred by the Outside Substantial Completion Date and Developer shall
nevertheless be endeavoring diligently to complete the Mall Improvements, then
so long as Mall II Buyer is not in default of any obligations under this
Agreement, Mall II Buyer shall be entitled to liquidated damages (the "INTERIM
LIQUIDATED DAMAGES") in the amount of $5,000 per day for each day after the
Outside Substantial Completion Date on which Substantial Completion has not
occurred up to and including the date that is six (6) months after the Outside
Substantial Completion Date and $10,000 per day for each day from and after said
date to and including the date that is one (1) year after the Outside
Substantial Completion Date on which Substantial Completion has not occurred.
During the one year period during which Interim Liquidated Damages are payable,
Developer shall also reimburse Mall II Buyer for actual out-of-pocket damages
incurred and paid to Tenants under said Tenant's Leases (including any reduced
rent, rent abatements or other rent concessions under said

                                       27
<Page>

Tenant's Leases) resulting from Developer's delay in achieving Substantial
Completion ("LEASE DAMAGES").

        (b) If Substantial Completion has not occurred on or before the date
that is one (1) year after the Outside Substantial Completion Date, subject to
extension for Force Majeure, Construction Delays and Buyer Delays, then Mall II
Buyer and Developer agree that it would be impracticable and extremely difficult
to ascertain the actual damage to Mall II Buyer as a result of the failure of
Developer to achieve Substantial Completion by such date and that the Buyer
Liquidated Damages Amount is a reasonable estimate of the damages which Mall II
Buyer will incur as a result of such failure and, in such an event, Developer
shall pay to Mall II Buyer the Buyer Liquidated Damages Amount and Developer
shall be responsible to pay the Lease Damages. The "BUYER LIQUIDATED DAMAGES
AMOUNT" as used in this Agreement shall mean one hundred million dollars
($100,000,000).

        7.2 OPENING DATE.

        (a) Commencing upon the notification from Developer to Mall II Buyer of
the Anticipated Completion Date as provided in Section 3.8, Mall II Buyer and
Developer shall negotiate in good faith, based on the work required to complete
the Phase II Mall and the Phase II Hotel/Casino, to agree on an appropriate date
for the Phase II Mall and the Phase II Hotel/Casino to open for business (the
"OPENING DATE"). Developer shall cause the Phase II Hotel Casino to open for
business no later than the Opening Date. "OPEN FOR BUSINESS" as used in
connection with the Phase II Hotel/Casino shall mean that the casino is open for
business to the general public and at least one thousand (1,000) guest rooms are
available for occupancy by hotel guests. The Opening Date shall be extended one
day for each day of delay due to Force Majeure, Construction Delays or Buyer
Delays. If Developer shall fail to cause the Phase II Hotel/Casino to Open for
Business by the Opening Date, as extended as described in the prior sentence,
Developer shall pay to Mall II Buyer the amount of $5,000 per day for each day
after the Opening Date on which the Phase II Hotel/Casino fails to Open for
Business up to and including the one hundred and eighty-first (181st) day
following the Opening Date and $10,000 per day for each day from the one hundred
and eighty-first (181st) day following the Opening Date through the one year
anniversary of the Opening Date on which the Phase II Hotel/Casino fails to Open
for Business. From and after the date that is one year after the Opening Date,
if the Phase II Hotel/Casino is not Open for Business, Developer shall reimburse
Mall II Buyer for any actual damages incurred as a result of the delayed opening
for business of the Phase II Hotel/Casino.

        (b) Mall II Buyer shall use commercially reasonable efforts to cause the
Phase II Mall to Open for Business on the Opening Date, but in no event shall
the Phase II Mall Open for Business later than the latest of (i) four (4) months
after the date on which Substantial Completion is achieved, (ii) the date on
which the Phase II Hotel/Casino opens for business or (iii) the Opening Date
(the "MALL OPENING Date"). "OPEN FOR BUSINESS" as used in connection with the
Phase II Mall shall mean that the Phase II Mall has held a public grand opening.
The Mall Opening Date shall be extended one day for each day of delay due to
Force Majeure or Developer Delays. If Mall II

                                       28
<Page>

Buyer shall fail to cause the Phase II Mall to Open for Business by the Mall
Opening Date, as extended as described in the prior sentence, Mall II Buyer
shall reimburse Developer for any actual damages incurred as a result of the
delayed opening for business of the Phase II Mall.

        (c) The provisions of this Section 7.2 shall survive the Closing.

                                   ARTICLE 8

                              AMENDED REA AND COREA

        8.1 AMENDED REA. The Phase II Mall is part of a complex consisting of
the Venetian Casino Resort and the Palazzo Casino Resort. The Venetian Casino
Resort and the Palazzo Casino Resort each include several component sections
each owned by a different Unit Owner. The REA is the document that governs the
relationship, including, among other things, cost allocations and easements,
among the various Unit Owners. Prior to the Closing, Developer, Mall II Buyer
and the other Unit Owners shall prepare an amendment and/or restatement of the
REA to be entered into by and among the Unit Owners (the "AMENDED REA") to
reflect the construction of the Palazzo Casino Resort and the acquisition of the
Membership Interests by Mall II Buyer. Negotiations regarding the Amended REA
will follow as soon as practicable following the date hereof and each of
Developer and Mall II Buyer must act in good faith and reasonably in connection
with such negotiations. The Amended REA shall amend the terms of the REA to
provide for, among other things, (i) appropriate mutual operating covenants,
(ii) joint marketing and advertising, (iii) certain shared casino or mall
operations, (iv) the sharing of customer information, (v) the joint purchasing
of insurance, (vi) shared security operations, (vii) easements, encroachments
and other similar rights necessary or desirable for the operation of the various
components of the Venetian Casino Resort and the Palazzo Casino Resort, (viii) a
requirement that Mall II LLC pay its share of those common maintenance, utility
costs and other items as set forth on SCHEDULE "15 attached hereto and made a
part hereof (subject to variables set forth in SCHEDULE "15), (ix) parking, (x)
that Mall I Buyer shall cause the governing documents between Mall I LLC and
Mall I Buyer and their respective lenders to provide that Developer and its
Affiliates are permitted transferees of Mall I LLC's interest in the Phase I
Mall or Mall I Buyer's interest in Mall I LLC and that Developer or any of its
Affiliates shall be permitted to assume such financing in connection with the
exercise by Developer of its rights under Section 21.2 and (xi) any other
matters that would be of mutual benefit to the Unit Owners. In the event that
the Unit Owners are not able to agree on the terms of the Amended REA the matter
shall be referred to an Independent Expert in accordance with the provisions of
Article 9.

        8.2 COREA. No later than thirty (30) days prior to the opening of the
Phase II Mall, unless Mall I LLC and Mall II LLC agree otherwise, there must be
in place an executed construction, operation and reciprocal easement agreement
("COREA") between Mall I LLC and Mall II LLC. Negotiations regarding the COREA
will follow as soon as practicable following the date hereof and each of Mall I
LLC and Mall II LLC must act in good faith and reasonably in connection with

                                       29
<Page>

such negotiations. The COREA must, among other things, (i) be an agreement that
a commercially reasonable owner of the Phase I Mall and of the Phase II Mall
would execute, (ii) provide that, unless the prior written consent of Mall I LLC
has been obtained, the Phase II Mall shall not contain more than five hundred
thousand (500,000) square feet of gross leasable area, (iii) contain guidelines
relating to the design of the Phase II Mall (including, without limitation, the
connection(s) between the Phase I Mall and the Phase II Mall), and relating to
alterations and maintenance of the Phase I Mall and the Phase II Mall, so that,
among other things, the malls are architecturally harmonious and constructed and
maintained in a first-class manner, (iv) provide for the joint maintenance,
leasing, marketing, management and operation, of the Phase I Mall and the Phase
II Mall, (v) require each of Mall I LLC and Mall II LLC to pay (A) all operating
and other expenses that are directly allocable to either mall and (B) an
equitable portion of all operating and other expenses that are not directly
allocable to either mall but otherwise relate to the "integrated mall" ("SHARED
MALL EXPENSES"), (vi) provide for approval of a leasing plan and, with respect
to all operating expenses that should appropriately be Shared Mall Expenses, an
operating budget prior to commencement of operation of the Phase II Mall and
each year thereafter, (vii) provide that each of Mall I LLC and Mall II LLC is
entitled to receive and retain, for its own account, all revenue generated by
the Phase I Mall or the Phase II Mall, as applicable, (viii) allow each of Mall
I LLC and Mall II LLC to sell and finance its mall and, in connection therewith,
to assign or mortgage its interest in the COREA, (ix) provide for the granting
of appropriate easements across each of the Phase I Mall and the Phase II Mall,
(x) contain provisions relating to restoration of the Phase I Mall and the Phase
II Mall after casualty and condemnation, (xi) contain a mechanism to resolve
disputes under the COREA and (xii) require Mall II LLC to grant to Mall I LLC an
easement for the location and operation by Mall I LLC of the gondola ride
through certain areas of the Phase II Mall. In the event that Mall I LLC and
Mall II LLC are not able to agree on the terms of the COREA the matter shall be
referred to an Independent Expert in accordance with the provisions of Article
9.

                                   ARTICLE 9

                        CONSULTATION; DISPUTE RESOLUTION

        9.1 CONSULTATION; MALL II BUYER'S SITE REPRESENTATIVE. The parties will
consult with each other regularly concerning the evolving design, respectively,
of the Mall Improvements and of the Build-Out and also of the construction of
the Mall Improvements and the Build-Out while in progress. For this purpose the
parties shall exchange drawings, specifications, shop drawings, submittals,
excerpts of meeting minutes, and other materials that may be necessary or
appropriate to further the purposes of this Agreement. Mall II Buyer shall
appoint a representative who shall be assigned full time to the Phase II Mall as
the on-site representative of Mall II Buyer (the "MALL II BUYER SITE
REPRESENTATIVE"). The Mall II Buyer Site Representative shall be the primary
point of contact between Developer and Mall II Buyer as to the matters
contemplated by this Agreement, including, without limitation, the delivery of
the Mall II Buyer Monthly Statement, the development of the Common Area Plans,
the Initial Demising Wall Plan and the Final Demising Wall Plan, coordinating
the Tenant Build-

                                       30
<Page>

Out Work by the Tenants, their contractors and subcontractors and any requested
changes to the Final Construction Drawings and Specs, the Initial Demising Wall
Plan, the Final Demising Wall Plan, the Standards Document or the Common Area
Plans. The Mall II Buyer Site Representative shall have authority to make
decisions and execute agreements in regard to the Phase II Mall, and to exercise
any rights of Mall II Buyer under this Agreement, on behalf of Mall II Buyer and
Developer shall be entitled to rely on any instructions, consents or approvals
given by the Mall II Buyer Site Representative as if they are the instructions
of Mall II Buyer. Each party may invite representatives of the other (including
the Mall II Buyer Site Representative) from time to time, to attend such party's
regular job or project meetings to discuss matters of interest or concern. This
Section shall not require disclosure of confidential or sensitive materials or
require attendance at meetings in which disputes with the other party,
unresolved positions, or matters not involving the other party are to be
discussed.

        9.2 RESOLUTION OF DISPUTES.

        (a) In the event there is a dispute among any of the parties (the
"DISPUTING PARTIES") regarding the amount of any Interim Payment and the
Disputing Parties cannot, with respect to such dispute, resolve such dispute
prior to the time set forth for payment of such Interim Payment, then the matter
in question shall be resolved in accordance with the further provisions of this
Section 9.2(a). In the event of any such disagreement, Developer and Mall II
Buyer shall promptly notify the Independent Expert (as defined below) of such
disagreement and of their desire that such disagreement be resolved by the
Independent Expert. Developer and Mall II Buyer shall each present to the
Independent Expert the amount they believe to be the correct amount of the
Interim Payment in dispute and any documentation necessary to support such
position. The Independent Expert may only decide in favor of the amount
presented by either Developer or Mall II Buyer, and may not make a
ruling/determination other than in favor of one of the two amounts presented.

        (b) In the event that there is a dispute among the Disputing Parties
that this Agreement provides will be resolved by an Independent Expert arising
out of or relating to this Agreement, other than those disputes in regard of the
amount of any Interim Payment described in Section 9.2(a) above. and the
Disputing Parties cannot, with respect to any such dispute, resolve such dispute
within the time period set forth in Section 9.3 of this Agreement, then the
matter(s) in question shall be resolved in accordance with the further
provisions of this 9.2(b). In the event of any such disagreement, the Disputing
Parties shall promptly notify the Independent Expert (as defined below) of such
disagreement and of their desire that such disagreement be resolved by the
Independent Expert. The Independent Expert shall be instructed to render its
decision within the time period set forth in Section 9.3 below after such
notification. Each of the Disputing Parties shall be entitled to present
evidence and arguments to the Independent Expert, which evidence and arguments
may include the relevant provisions hereof. During the pendency of such
dispute-resolution procedure, the Disputing Parties shall continue their
performance under this Agreement, including with respect to the matter that is
the subject of such procedure. The determination of the Independent Expert
acting as above provided (i) shall be conclusive and binding upon the

                                       31
<Page>

parties to this Agreement and (ii) shall in no event modify, amend or supplement
this Agreement in any manner. The Independent Expert shall be required to give
written notice to the Disputing Parties stating its determination, and shall
furnish to each party to this Agreement a signed copy of such determination.
Each of the Disputing Parties shall pay half of the fees and expenses of the
Independent Expert and all other expenses of the above-described dispute
resolution procedure (not including the attorneys' fees, witness fees and
similar expenses of the Disputing Parties, which shall be borne separately by
each of the Disputing Parties).

        9.3 SUBMISSION OF DISPUTES TO INDEPENDENT EXPERT.

        (a) SUBMISSIONS ON AN EXPEDITED BASIS. Disputes referred to the
Independent Expert pursuant to the terms of this Agreement which are reasonably
likely to cause a delay in Substantial Completion, other than the determination
of Substantial Completion itself which shall be made in accordance with Section
3.8, may be submitted for determination by an Independent Expert on an expedited
basis at any time if the Disputing Parties have been unable to settle such
dispute. The Independent Expert shall deliberate on an expedited basis on such
matters and shall render its decision within five (5) Business Days after
notification of the dispute. If the Independent Expert notifies the Disputing
Parties that it is impracticable to make a determination of such dispute within
such five (5) Business Day period, the deadline for the rendering of a decision
shall be extended as long as necessary as the Independent Expert proceeding
diligently shall take to resolve such dispute. Notwithstanding the submission of
such disputes to the Independent Expert, the Disputing Parties may proceed with
construction in regard to the disputed matter in the manner in which Developer
(in connection with disputes regarding Substantial Completion, the Mall
Improvements or the Landlord Build-Out) has determined, in good faith, is
appropriate and in compliance with this Agreement. If the Independent Expert
determines that one of the Disputing Parties has proceeded in a manner that is
in breach of the terms of this Agreement, such party shall be liable to the
other for all loss, liability, damage, cost, or expense (including Fees and
Costs) which the other party may suffer, or which may be asserted against such
party arising from such breach.

        (b) SUBMISSIONS ON AN ORDINARY BASIS. In any matter other than those set
forth in Section 9.3(a) above that this Agreement specifies shall be resolved by
an Independent Expert, in the event that the Disputing Parties cannot, without
respect to any such dispute, resolve such dispute (a) by the Closing Date, the
applicable Interim Payment Date, the Earn-Out Date or the Final Date, with
respect to disputes regarding the Closing Payment, any Adjustment Payment, the
Earn-Out Payment or the Recalculated Earn-Out, respectively, or (b) within
thirty (30) days, then the matter(s) in question shall be resolved in accordance
with Section 9.2. The Independent Expert shall be instructed to render its
decision within thirty (30) days (or any shorter time reasonably agreed to by
the Disputing Parties) after such notification.

        9.4 IDENTITY OF INDEPENDENT EXPERT. As used herein, the "INDEPENDENT
EXPERT" shall mean (a) with respect to any dispute pertaining to architectural,
construction or engineering matters, an appropriately licensed and/or

                                       32
<Page>

registered (as applicable), reputable and independent architect or engineer; (b)
with respect to any dispute pertaining to hotel, casino, restaurant or retail
complex operation or management, a reputable and independent Person with
experience in pertinent commercial real estate operation and management; and (c)
with respect to any other dispute, a licensed, reputable and independent
certified public accountant, in each of (a), (b) or (c) reasonably acceptable to
the Disputing Parties. In all events, the Independent Expert shall (i) not be
affiliated with Developer, Mall II LLC or Mall II Buyer (or any Affiliate of any
of them) and (ii) have at least ten (10) years of relevant experience and
expertise with respect to large commercial real estate projects in Las Vegas,
Nevada and/or Clark County, Nevada. In the event that Developer and Mall II
Buyer can not agree on the selection of an Independent Expert to resolve
disputes under Section 9.2(a) or (b) above, each of Developer and Mall II Buyer
shall choose an individual who satisfies the Independent Expert requirements of
this Section 9.4. Those individuals so chosen shall confer in good faith to
select a third individual who shall be the Independent Expert for the purposes
of this Agreement and the choice so made shall be binding on Mall II Buyer and
Developer. Proceedings before or involving dispute resolution under this Article
in and of themselves shall not constitute events of Force Majeure.

        9.5 The provisions of this Article 9 shall survive the Closing.

                                   ARTICLE 10

                            MALL II BUYER CONDITIONS

        10.1 CONDITIONS TO MALL II BUYER'S OBLIGATIONS. Mall II Buyer's
obligation to consummate the Closing under this Agreement shall be subject to
satisfaction of each of the following conditions at or before the Closing:

        (a) Developer shall have caused a commercial subdivision of the Palazzo
Casino Resort in order to cause the Phase II Mall and the Phase II Hotel/Casino
to become legal parcels which are separate and distinct from each other and from
the Phase II Land capable of being conveyed in fee simple.

        (b) Developer shall have formed Mall II LLC and conveyed Developer's fee
interest in the Fee Mall Space and Developer's leasehold interest in the
Leasehold Mall Space to Mall II LLC.

        (c) Substantial Completion shall have occurred.

        (d) Title Insurer shall be willing to issue an owner's policy of title
insurance in the amount of the Closing Payment, subject to payment of premiums,
insuring fee title to the Fee Mall Space and leasehold title to the Leasehold
Mall Space and the Casino Shops as being vested in Mall II LLC, free of
Encumbrances other than Permitted Encumbrances, which policy shall include a
non-imputation endorsement in Title Insurer's standard form and reasonably
acceptable to Mall II Buyer.

                                       33
<Page>

        (e) Developer shall have executed and delivered to Mall II Buyer an
Assignment of the Membership Interests in a form reasonably acceptable to Mall
II Buyer.

        (f) All representations and warranties of Developer (without reference
to any modifications thereof contained in Developer's Representation
Certificate) contained in this Agreement that are required to be true, correct
and complete as of the Closing Date shall be true, correct and complete in all
material respects subject, however, to matters known to Mall II Buyer as of the
date hereof.

        (g) Developer shall not be in default in any material respect, as of the
Closing Date, under Developer's covenants, agreements and undertakings on behalf
of itself or Mall II LLC in this Agreement.

        (h) Developer shall have executed and delivered all Closing Instruments
required to be executed and delivered by Developer at or prior to the Closing.

        (i) Developer or H/C I Owner shall have obtained such insurance
coverage, if any, that it is required to obtain pursuant to the terms of the
Amended REA; and if and to the extent that such policy is not yet effective,
Developer shall have in force a policy of builder's risk insurance which shall
cover the Mall Improvements until such time as the foregoing insurance coverage
required by the Amended REA becomes effective. In either case, a certificate of
such policy shall have been delivered to Mall II Buyer.

        (j) There shall exist no Hazardous Materials in or on the Phase II Land
or the Development that would prevent Use and Occupancy of the Phase II Mall
and/or the Common Elements by Mall II Buyer.

        (k) No petition for relief or similar Legal Proceeding has been filed
(unless dismissed within 60 days) pursuant to the United States Bankruptcy Code
with respect to Mall II LLC or the Developer and there shall be no binding
injunction, order or judgment of any court having proper jurisdiction
prohibiting Mall II Buyer from consummating the Closing.

        (l) Developer shall have delivered a certificate stating that it is not
a "foreign person" within the meaning of Section 1445 of the Internal Revenue
Code, as amended.

        (m) Developer and Mall II LLC shall have entered into the Master Lease
Agreement and a memorandum thereof in recordable form shall have been delivered
to the Title Insurer for recording.

        (n) Las Vegas Asia Corp.("TSUNAMI") shall have surrendered its leasehold
interest in the Phase I Mall and shall have delivered possession of such space
to Mall I LLC if the same is required pursuant to Section 15.14 of this
Agreement.

                                       34
<Page>

        (o) Mall II LLC shall have received from each lender holding a mortgage
encumbering the fee interest in the Casino Shops an executed subordination,
non-disturbance and attornment agreement (the "SNDA") in form reasonably
acceptable to Mall II Buyer, with respect to the Master Lease Agreement.
Developer hereby agrees to use commercially reasonable efforts to obtain such
SNDA from any such lender.

        (p) All exterior barricades, lifts and hoists shall have been removed to
the extent that the same interfere with the Phase II Hotel/Casino and/or the
Phase II Mall being Open for Business, the Phase II Automobile Parking Area
shall be open and all building systems in the Phase II Mall (including, without
limitation, HVAC and life and safety) shall have been tested and verified as
being in working order.

        (q) All Tenant Payments held by Developer pursuant to Section 16.3(c),
if any, shall be transferred to an account maintained in the name of Mall II
LLC.

        (r) The Phase II Hotel/Casino shall be Open for Business.

        (s) Any other condition to Mall II Buyer's obligations which are
specifically set forth in this Agreement shall have been fulfilled.

                                   ARTICLE 11

                              DEVELOPER CONDITIONS

        11.1 CONDITIONS TO DEVELOPER'S OBLIGATIONS. The obligations of Developer
to be performed at the Closing shall be subject to satisfaction of the following
conditions:

        (a) All representations and warranties of Mall II Buyer in this
Agreement shall be true, correct, and complete in all material respects as of
the Closing Date.

        (b) Mall II Buyer shall not be in default in any material respect, as of
the Closing Date, under any covenant, agreement or undertaking of Mall II Buyer
under this Agreement.

        (c) Mall II Buyer shall have executed and delivered all Closing
Instruments required to be executed and delivered by Mall II Buyer at or prior
to the Closing.

        (d) Mall II Buyer shall have delivered the Closing Payment to Developer
as set forth in Section 20.2(a) of this Agreement.

        (e) Any other conditions to Developer's obligations which are
specifically set forth in this Agreement shall have been fulfilled.

                                       35
<Page>

                                   ARTICLE 12

                              WAIVER OF CONDITIONS

        12.1 MALL II BUYER'S WAIVER. Mall II Buyer shall have the right to waive
compliance by Developer and/or any other party with any condition set forth in
Article 10.

        12.2 DEVELOPER'S WAIVER. Developer shall have the right to waive
compliance by Mall II Buyer of any condition set forth in Article 11.

        12.3 WRITTEN WAIVER. Any waiver under Section 12.1 or 12.2 must be in
writing and must refer specifically to the condition being waived. If the
Closing occurs, the conditions in Articles 10 and 11 shall be deemed to have
been satisfied unless specified to the contrary in writing, whether or not
specifically waived; provided, however, that neither party shall be released
from any obligations which survive the Closing.

        12.4 NOTICE BY DEVELOPER. Subject to Section 15.12, if, before the
Closing Date, either party becomes aware that any of Developer's representations
and warranties in this Agreement are untrue, incorrect, or incomplete in any
material respect (provided that such representations and warranties were true,
correct and complete when originally made), such party shall give notice to the
other party as promptly as practicable. Thereafter, Developer shall have the
right to cure or correct the problem prior to the Closing Date.

        12.5 NOTICE BY MALL II BUYER. Subject to the last two sentences of
Section 16.1, if, before the Closing Date, either party becomes aware that any
of Mall II Buyer's representations and warranties in this Agreement are untrue,
incorrect or incomplete in any material respect (provided that such
representations and warranties were true, correct and complete when originally
made), such party shall give notice to the other party as promptly as
practicable. Thereafter, Mall II Buyer shall have the right to cure or correct
the problem prior to the Closing Date.

        12.6 COVENANT TO SATISFY CONDITIONS. Developer and Mall II Buyer each
hereby agree to use commercially reasonable efforts to cause each of the
conditions precedent to the obligations of the other party to be fully
satisfied, performed and discharged on and as of the Closing Date, except that
neither party shall have any obligation to expend any funds or incur any
liabilities or obligations which it would not otherwise be required to spend or
incur under the provisions of this Agreement.

                                       36
<Page>

                                   ARTICLE 13

                                     CLOSING

        13.1 THE CLOSING. The Closing shall take place at the offices of
Developer's counsel (or at another location in Clark County, Nevada or New York
City, New York designated by Developer) at 10 am on the Mall Opening Date, time
being of the essence (the "CLOSING DATE").

        13.2 DELIVERY OF POSSESSION. Developer shall deliver possession of the
Phase II Mall to Mall II Buyer at the Closing (if Mall II Buyer is not already
in possession), subject only to the Permitted Encumbrances, the Site Logistics
Procedures and this Agreement.

                                   ARTICLE 14

                       CLOSING DELIVERIES; RELATED MATTERS

        14.1 DEVELOPER'S DELIVERIES. Subject to the terms of this Agreement,
Developer shall execute and deliver to Mall II Buyer or Mall II LLC, as
applicable, at or prior to the Closing:

        (a) an assignment of the Membership Interests to Mall II Buyer (the
"ASSIGNMENT");

        (b) a General Assignment/Bill of Sale assigning to Mall II LLC the
Exclusive Mall Equipment;

        (c) the Amended REA;

        (d) the Developer's Representation Certificate;

        (e) the Developer's Warranty, if applicable;

        (f) notices to Tenants from the appropriate parties informing them of
the termination of any lockbox agreements in effect immediately prior to the
Closing and instructing Tenants to pay rent in such a manner as directed by Mall
II Buyer;

        (g) Developer's copies of any Leases executed by Mall II LLC and
Tenants;

        (h) Developer's copies of any Service Contract that shall survive the
Closing;

        (i) all sales tax, transfer tax and other tax returns, if any, which the
Developer is required by law to execute and deliver, either individually or
together

                                       37
<Page>

with Mall II Buyer, to any Government Authority as a result of the sale of the
Membership Interests;

        (j) All records and files which are in the possession of the Developer
relating to the operation and maintenance of the Phase II Mall, including
without limitation, to the extent in the possession of Developer, current tax
bills, current water, sewer, utility and fuel bills, payroll records, billing
records for Tenants, Tenant files, repair and maintenance records and the like
which affect or relate to the Phase II Mall, plans, drawings, blue prints and
specifications for the Phase II Mall, certificates of occupancy and other
licenses and permits and keys to the Phase II Mall; and

        (k) any other instruments or documents to be executed and/or delivered
by Developer pursuant to SCHEDULE "7" or other provisions of this Agreement.

        14.2 MALL II BUYER'S DELIVERIES. Subject to the terms of this Agreement,
Mall II Buyer shall execute and/or deliver to Developer at or prior to the
Closing:

        (a) the Closing Payment;

        (b) the Amended REA;

        (c) All sales tax, transfer tax and other tax returns, if any,
certificates of value and similar documents which Mall II Buyer is required by
law to execute and deliver, either individually or together with Developer to
any Government Authority as a result of the purchase of the Membership
Interests.

        (d) Counterparts of each of the instruments and documents listed in
Section 14.1 for which Mall II Buyer's execution is necessary to give effect to
such instrument or documents;

        (e) Any payment for change costs required pursuant to Sections 3.3(b) or
3.3(c); and

        (f) any instruments or documents to be executed and/or delivered by Mall
II Buyer pursuant to SCHEDULE "7" or any other provisions of this Agreement.

        14.3 UTILITY DEPOSITS AND ESCROWS. If applicable, at the Closing,
Developer shall assign to Mall II LLC all deposits or escrows held for
Developer's account at or by any public utility company in connection with
public utility services furnished solely to the Phase II Mall. Mall II LLC shall
pay, or Developer or Mall II Buyer shall cause Mall II LLC to pay, to Developer,
at the Closing, for the amount of the deposits or escrows so assigned and will
become responsible for public utility charges due thereafter with respect to the
Phase II Mall. Alternatively, Developer may terminate such public utility
accounts. Prior to the Closing Date, Developer shall notify all such public
utility companies in writing (with copies to Mall II LLC) of the applicable
transfer of service.

                                       38
<Page>

        14.4 DELIVERY OF PHASE II MALL DOCUMENTS. At the Closing subject to the
terms of this Agreement, Developer shall deliver to Mall II LLC Developer's
originals (or, if Developer has no originals, true and complete copies) of the
Phase II Mall Documents; provided, however, that to the extent certain of the
operating manuals that constitute the Phase II Mall Documents are not available
to Developer at the time of Closing, Developer shall deliver them to Mall II
Buyer as promptly as possible thereafter.

        14.5 PERFORMANCE OF COVENANTS AND RESPONSIBILITIES. At the Closing,
Developer shall keep and perform all covenants and responsibilities to be
performed at the Closing under this Agreement by Developer or by Mall II LLC.

        14.6 DELIVERY OF SURVEY. At Developer's expense, Developer shall deliver
to Mall II LLC, at the Closing, an "as-built" survey (dated or updated to a date
not earlier than sixty (60) days before the Closing Date) which shows the Phase
II Mall as constructed within the Building at the point of construction as of
such date. Upon completion of construction of the Development, Developer shall
deliver a final version of such survey, showing the Development "as-built."

        14.7 APPROVALS, ETC. Developer shall use commercially reasonable efforts
to obtain or complete, as applicable, all approvals, authorizations, consents or
other actions by or filings with any Person (if any) which are required to be
obtained or completed by Developer prior to or in connection with the execution
and delivery of this Agreement or any of the Closing Instruments or in
connection with any other action required to be taken by Developer hereunder at
or before the Closing, including those listed in SCHEDULE "6" (if any), shall
have been obtained or completed, as the case may be; however, it shall not be a
condition to Mall II Buyer's obligations under this Agreement that any such
approval, authorization or consent shall be obtained, but Developer shall be
obligated to pay and indemnify Mall II Buyer from and against any damages,
penalties or other sums that may be payable to the other Party by reason of
Developer's failure to obtain such consent, which obligations shall survive the
Closing.

                                   ARTICLE 15

                         REPRESENTATIONS AND WARRANTIES
                        OF DEVELOPER; CERTAIN AGREEMENTS

        15.1 REPRESENTATIONS AND WARRANTIES OF DEVELOPER. Developer represents
and warrants to Mall II Buyer as follows:

        (a) The representations and warranties of Developer set forth in
SCHEDULE "10," Part One attached hereto and made a part hereof, regarding its
organization and ownership, authorization of this Agreement and other matters,
are true and correct as of the date hereof. The representations and warranties
of Developer set forth in SCHEDULE "10," Part Three attached hereto and made a
part hereof, regarding the organization and ownership of Mall II LLC,
authorization of this Agreement on behalf of Mall II LLC and other matters,
shall be true and correct as of the Closing Date.

                                       39
<Page>

        (b) Except as set forth in SCHEDULE "6," there are no approvals,
authorizations, consents or other actions by or filings with any Person which
are required to be obtained or completed by Developer in connection with the
execution and delivery of this Agreement or any of the Closing Instruments or in
connection with any other action required to be taken by Developer hereunder at
or before the Closing.

        (c) Except as set forth in SCHEDULE "6," to Developer's actual
knowledge, there are no outstanding judgments, orders, writs, injunctions or
decrees of any Government Authority, no pending Legal Proceedings, and no
proceedings to foreclose any Mortgage, security instrument, lien or other claim,
in each case, against Developer in connection with the Phase II Land or the
Development.

        (d) Developer has received no written notice of any taking, or proposed
taking, of the Phase II Land or the Phase II Mall in Condemnation (excluding
sidewalk or street takings).

        (e) Except as set forth on SCHEDULE "18," attached hereto and made a
part hereof, Developer has not entered into any leases with respect to the Phase
II Mall and no third party has any right, option or election to rent space in
the Phase II Mall.

        (f) Developer is not a "foreign person" within the meaning of Section
1445 of the Internal Revenue Code, as amended.

        (g) With respect to the Membership Interests and Mall II LLC:

        (i) The Membership Interests shall constitute all of the membership and
management interests in Mall II LLC at all times after the formation of Mall II
LLC.

        (ii) Developer will upon completion, and as of the Closing Date, deliver
to Mall II Buyer a true, correct and complete copy of the limited liability
company agreement and certificate of formation of Mall II LLC, as amended.
Developer and Mall II Buyer shall consult as to the form of limited liability
company agreement of Mall II LLC and Mall II Buyer shall have reasonable
approval rights as to the form of such Agreement except to the extent that
certain provisions are required by a lender in order to obtain the necessary
financing for the development, which provisions shall not require Mall II
Buyer's consent.

        (iii) As of Closing, the Membership Interests shall be owned by
Developer, free and clear of all liens, security interests, options and
encumbrances and have not been pledged or hypothecated as of the date hereof to
any third party (except for any pledge or hypothecation that will be released at
or prior to Closing Date). Neither Developer nor Mall II LLC will grant, issue
or enter into and neither Developer nor Mall II LLC will be bound by any
options, rights, commitments, agreements, arrangements or undertakings of any
kind (other than this Agreement) which will obligate or could obligate Developer
or Mall II LLC to transfer the Membership Interests or any part thereof or
interest therein or grant to any other person or entity any voting, management
or other right in respect of the Membership Interests.

                                       40
<Page>

        (iv) Mall II LLC will pay all Impositions and other federal, state and
local taxes as they become due.

        (v) Mall II LLC will elect to be taxed as a partnership.

        (h) With respect to the REA:

        (i) SCHEDULE "12" attached hereto and made a part hereof is a true,
correct and complete, but non-executed, copy of the REA.

        (ii) As of the date hereof, the REA is in full force and effect, and
Developer has not received written notice from any party to the REA that
Developer has defaulted in performing any of its material obligations under the
REA. To Developer's knowledge, as of the date hereof, no material default exists
under the REA on the part of any of the parties thereto.

        (iii) There are no unpaid obligations of Developer due and payable under
or in respect of the REA.

        15.2 MORTGAGES. Developer shall pay and discharge at or prior to the
Closing any and every Mortgage against the Mall II Unit (and no Mortgage shall
constitute a Permitted Encumbrance).

        15.3 SERVICE CONTRACTS. At or prior to the Closing, Developer shall
terminate all Service Contracts (effective as of the soonest possible date),
other than those listed on SCHEDULE "4" attached hereto and made a part hereof
and any other Service Contract which Mall II Buyer elects in its sole discretion
by notice on or before sixty (60) days prior to Closing to have Mall II LLC
assume. Developer shall pay all termination costs in connection therewith.

        15.4 EMPLOYEES. Developer will have no employees engaged in the
operation, management, or repair of the Building who are required to become
employees of Mall II Buyer or Mall II LLC at or after the Closing. Mall II LLC
will not have employees at any time, without the prior written consent of Mall
II Buyer, not to be unreasonably withheld or delayed.

        15.5 TITLE. Developer will have good title (free of Encumbrances other
than Permitted Encumbrances) to all items of Exclusive Mall Equipment on the
Closing Date. Developer will own and have full authority to use the Phase II
Mall Documents and to transfer the same to Mall II LLC as set forth in this
Agreement.

        15.6 HAZARDOUS MATERIALS. Developer shall provide Mall II Buyer with a
copy of reports, inspections, or analyses concerning the presence (or possible
presence) of Hazardous Materials in or on the Phase II Land or the Building
which Developer commissions or receives with reasonable promptness after receipt

                                       41
<Page>

thereof. If requested by Developer, Mall II Buyer shall reimburse Developer for
the reasonable costs of copying such documents for Mall II Buyer.

        15.7 LEGAL PROCEEDINGS. Developer shall notify Mall II Buyer of any
Legal Proceedings against Developer in connection with the Phase II Land or the
Development (other than "slip and fall" or similar Legal Proceedings covered by
insurance or other Legal Proceedings which will not adversely affect Developer's
ability to convey the Membership Interests to Mall II Buyer or performance of
Developer's obligations under this Agreement), or any notice of Condemnation (or
proposed Condemnation) of the Phase II Land or the Building in each case
promptly after receipt of the same (and upon request Developer shall provide
Mall II Buyer with copies of relevant documents to the extent in Developer's
possession).

        15.8 LIENS. Developer shall bond or otherwise discharge of record, at
Developer's expense, any liens filed against the Phase II Mall before or after
the Closing by any contractor or subcontractor of Developer (or any other
Persons claiming through or under Developer).

        15.9 NO IMPLIED REPRESENTATIONS. Mall II Buyer acknowledges that except
as expressly set forth in this Agreement, neither Developer nor any agent or
representative or purported agent or representative of Developer has made, and
Developer is not liable for or bound in any manner by, any express or implied
warranties, guaranties, promises, statements, inducements, representations or
information (including, without limitation, any information set forth in
materials heretofore furnished to Mall II Buyer by Goldman Sachs) pertaining to
the Mall Improvements, the Phase II Mall, the Palazzo Casino Resort or any part
thereof, the physical condition thereof, environmental matters, income, expenses
or the operation thereof, the uses which can be lawfully made of the same under
applicable zoning or other laws or any other matter or thing with respect
thereto. Without limiting the foregoing, Mall II Buyer acknowledges and agrees
that, except as expressly set forth in this Agreement, Developer is not liable
for or bound by (and Mall II Buyer has not relied upon) any verbal or written
statements, representations, or offering materials or any other information
respecting the Phase II Mall or the Palazzo Casino Resort furnished by Developer
or any broker, employee, agent, consultant or other person representing or
purportedly representing Developer. If Developer or its agents have delivered or
hereafter deliver to Mall II Buyer or its agents any information, report,
survey, analysis or similar documentation prepared by a third party unrelated to
Developer, Developer neither expressly or impliedly warrants or represents to
Mall II Buyer the truth, accuracy or completeness thereof and expressly
disclaims any liability whatsoever with respect thereto or any obligation
independently to investigate the matters contained therein; and Mall II Buyer
hereby acknowledges that Developer has or is providing such information,
reports, surveys, analysis or other third-party documents to Mall II Buyer as an
accommodation only and that Mall II Buyer shall be responsible for the
verification and review thereof. Nothing contained in this Section 15.9 shall be
deemed to impair, limit or otherwise affect Mall II Buyer's rights under this
Agreement in respect of the representations and warranties of Developer set
forth in this Agreement and the other provisions hereof binding upon Developer,
and the disclaimers

                                       42
<Page>

of this Section15.9 shall not apply to any information so represented or
warranted by Developer. The provisions of this Section 15.9 shall survive the
Closing Date or any termination of this Agreement.

        15.10 KNOWLEDGE. All representations and warranties made herein by
Developer which are based on Developer's knowledge are made, and are hereby
acknowledged by Mall II Buyer to be made, to the actual knowledge of Robert
Goldstein and Harry Miltenberger, without independent investigation regarding
the facts contained therein.

        15.11 DEVELOPER'S OBLIGATIONS TO CONSTRUCT MALL IMPROVEMENTS. So long as
this Agreement is in full force and effect and Mall II Buyer is not in material
default, Developer shall not construct any improvements in the Mall Space other
than the Mall Improvements for use as a retail mall in accordance with this
Agreement.

        15.12 SURVIVAL OF DEVELOPER'S WARRANTIES, ETC.

        (a) Unless otherwise specified in connection with a representation or
warranty, all of Developer's representations and warranties contained in this
Article 15 (other than those contained in Sections 15.1(a), 15(b), 15(c) and
15.1(g), which shall survive the Closing Date without limitation as to time), as
remade as of the Closing Date as provided in Section 15.12(c) and subject to any
modifications thereof made in any certificate provided for in said Section
15.12(c), shall survive until one (1) year after the Closing Date; provided,
however, that Developer's liability for any breach of such warranties,
representations and certifications shall not expire as to any breach or alleged
breach thereof if notice of such breach or alleged breach is given by Mall II
Buyer to Developer prior to one (1) year after the Closing Date and, if such
notice is given, legal proceedings are instituted in respect of such breach or
alleged breach within six (6) months after such notice is given. Developer's
obligations to perform the Landlord Build-Out Work and to pay Leasing Costs
shall survive until the Earn-Out Date and shall apply to all Leases executed
prior to the Earn-Out Date, with respect to Landlord Build-Out Work and Leasing
Costs which are to be performed or are incurred before the Earn-Out Date.

        (b) Notwithstanding anything to the contrary set forth in this Article
15, subject to the last sentence of this Section 15.12(b), (i) Developer shall
have no liability to Mall II Buyer for breach of any warranty and representation
set forth in this Article 15 unless and except to the extent that the damages
due to Mall II Buyer by reason of all such breaches exceed Two Hundred Fifty
Thousand Dollars ($250,000) (the "BASKET"), (ii) in no event shall Developer be
liable to Mall II Buyer for consequential or punitive damages in respect of any
such breach and (iii) in no event shall Developer's liability to Mall II Buyer
for all such breaches exceed Two Million Dollars ($2,000,000) (the "CAP").
Notwithstanding anything to the contrary set forth herein, the limitations on
the Basket and Cap shall not apply to a breach of a representation or warranty
contained in Sections 15.1(a), 15.1(b), 15.1(c) or 15.1(g).

                                       43
<Page>

        (c) All of Developer's representations and warranties set forth in this
Article 15 shall be remade on and as of the Closing Date in Developer's
Representation Certificate (the "DEVELOPER'S REPRESENTATION CERTIFICATE") in the
form of EXHIBIT B attached hereto and made a part hereof, which certificate
shall be delivered to Mall II Buyer on the Closing Date. Notwithstanding the
foregoing or anything else set forth in this Agreement, if any matter or event
shall have occurred between the date hereof and the Closing Date or Developer
shall otherwise become aware of any fact which makes any such warranty or
representation untrue in any material respect, Developer shall have the duty to
disclose such fact in Developer's Representation Certificate, and if Developer
does so, Developer shall not be liable to Mall II Buyer following the Closing
Date for the breach of the warranty or representation in question which results
from the occurrence or existence of such fact, but in no event shall Mall II
Buyer be obligated to close hereunder unless the conditions precedent to Mall II
Buyer's obligation to close set forth in this Agreement (including, without
limitation, in Section 15.1(a)) shall have been fulfilled.

        (d) Notwithstanding anything to the contrary set forth in this Article
15 or elsewhere in this Agreement, if prior to the Closing Date, Mall II Buyer
has or obtains knowledge that any of Developer's warranties or representations
set forth in this Article 15 is untrue in any respect, and Mall II Buyer
nevertheless proceeds with the Closing, then the breach by Developer of the
warranties, representations or certifications as to which Mall II Buyer shall
have or obtained such knowledge shall be waived by Mall II Buyer and Developer
shall have no liability to Mall II Buyer or its successors or assigns in respect
thereof.

        15.13 INDEMNIFICATION. Developer shall, at Developer's expense,
indemnify, defend and hold harmless Mall II LLC from and against any loss,
liability, damage, cost, or expense (including Fees and Costs) which Mall II LLC
may suffer, or which may be asserted against Mall II LLC, in whole or in part by
reason of, or in connection with any liabilities, obligations, debts, claims,
causes of action, judgments and damages which may be asserted against, imposed
on or incurred by Mall II LLC after the Closing Date, and which do not result
from an act or omission of Mall II Buyer prior to closing, by reason of any of
the following: (i) any obligation of Mall II LLC for borrowed money which was
incurred prior to the Closing; (ii) any claims made against Mall II LLC by any
party with respect to any period prior to the Closing Date; (iii) all
obligations and payments due from Mall II LLC to trade creditors with respect to
any period prior to the Closing Date; (iv) all obligations with respect to
existing litigation against Mall II LLC, or any litigation in connection with
the actions or omissions of Mall II LLC, instituted against Mall II LLC on or
after the Closing Date to the extent based on any event occurring prior to the
Closing Date; (v) any income, excise or franchise taxes or any other federal,
state or local taxes payable by Mall II LLC in respect of any period prior to
the Closing Date; (vi) any other liabilities, obligations, debts, claims, causes
of action, judgments or damages which may be imposed upon, incurred by or
asserted against Mall II LLC and which are based on any event occurring prior to
the Closing Date; (vii) any fine, penalty or the like that is imposed or
assessed by a governmental authority for the period prior to the Closing Date,
whether or not imposed or assessed

                                       44
<Page>

after the Closing Date; and (viii) any liabilities relating to any employees of
Developer or Mall II LLC to the extent their employment relates to the period
prior to the Closing Date, and any liabilities under employee benefit plans or
collective bargaining agreements of Developer or Mall II LLC with respect to
such employment prior to the Closing Date. Notwithstanding the foregoing, but
without limiting any indemnification expressly provided for in Section 3.5 of
this Agreement, in no event shall the indemnification provided for in this
Section 15.13 apply to any claim, liability, obligation, debt, cause of action,
judgment or damage asserted against or imposed upon Mall II Buyer or Mall II LLC
under or in respect of any Lease or on account of the Landlord Build-Out, except
to the extent that Developer is obligated to pay any Leasing Costs or undertakes
to construct the Landlord Build-Out pursuant to the terms of this Agreement.

        15.14 TSUNAMI. If it is necessary that Tsunami surrender its leasehold
interest in the Phase I Mall because it is anticipated that its demised space or
a portion thereof will need to be occupied by an anchor tenant in accordance
with the Common Area Plan, the Initial Demising Wall Plan, the Final Demising
Wall Plan agreed to by Developer and Mall II Buyer, or any Lease executed by
Mall II LLC in accordance with the provisions hereof, Developer shall use
commercially reasonable efforts at Developer's sole expense to obtain the
surrender of such leasehold interest. If it is not necessary for Tsunami to
surrender its leasehold interests as aforesaid, or if Tsunami surrenders its
leasehold interest and not all of its space is required for such anchor tenant,
Mall II Buyer and Developer agree that such space (or the aforesaid unused
portion of such space) shall remain part of the Phase I Mall notwithstanding
anything in this Agreement to the contrary. If Tsunami does surrender all or a
portion of its leasehold interest, then the surrendered portion anticipated to
be used for the anchor tenant shall be considered part of the Phase II Mall.

        15.15 MISCELLANEOUS COVENANTS OF DEVELOPER.

        (a) From the date hereof until the Closing, Developer shall not (a)
permit Mall II LLC to enter into, modify or amend any Lease except with Mall II
Buyer's prior written consent, (b) enter into any agreement the effect of which
is to cause Developer to be unable to assign the Membership Interests to Mall II
Buyer, or (c) amend any of the organizational documents of Mall II LLC except as
Developer may be required by a lender to amend the same in order to obtain the
necessary financing.

        (b) Subsequent to the Closing, Developer shall prepare timely and file,
or cause to be prepared and timely filed, all federal, state and local income
tax returns for Mall II LLC for the period ending on the Closing Date and pay
all amounts due as shown on said returns, which obligations shall survive the
Closing.

                                       45
<Page>

                                   ARTICLE 16

                         REPRESENTATIONS AND WARRANTIES
                      OF MALL II BUYER; CERTAIN AGREEMENTS

        16.1 REPRESENTATIONS AND WARRANTIES OF MALL II BUYER. Mall II Buyer
represents and warrants to Developer as follows:

        (a) SCHEDULE "10," Part Two, which sets forth representations and
warranties by Mall II Buyer concerning its organization and ownership,
authorization of this Agreement, and other matters, is incorporated herein by
reference.

        (b) Except as set forth in SCHEDULE "6," there are no approvals,
authorizations, consents or other actions by or filings with any Person which
are required to be obtained or completed by Mall II Buyer in connection with the
execution and delivery of this Agreement or any of the Closing Instruments or in
connection with any other action required to be taken by Mall II Buyer hereunder
at or before the Closing.

        (c) To Mall II Buyer's actual knowledge, there are no outstanding
judgments, orders, writs, injunctions, or decrees of any Government Authority,
no pending Legal Proceedings or material threats of Legal Proceedings, against
Mall II Buyer which would have a material adverse effect on Mall II Buyer's
performance of its obligations under this Agreement or the Closing Instruments.

        (d) No petition for relief or similar Legal Proceeding has been filed
(and not dismissed within 60 days) pursuant to the United States Bankruptcy Code
with respect to Mall II Buyer.

The representations and warranties of Mall II Buyer in this Section are true,
correct, and complete in all material respects as of the date of this Agreement.
Before the Closing Date, Mall II Buyer shall give Developer updates of SCHEDULES
"6" AND "10" so that, with the information and revisions then reflected in such
updates, the representations and warranties in this Section shall be true,
correct and complete as of the Closing Date.

        16.2 LIENS. Developer shall bond or otherwise discharge of record, at
Developer's expense, any liens filed against the Building in connection with the
Landlord Build-Out or any contractor or subcontractor of Developer (or any other
Persons claiming through or under Developer). Developer and Mall II Buyer shall
cooperate in order to cause each Tenants to bond or otherwise discharge of
record, at such Tenant's expense, any liens filed against the Building in
connection with the Tenant Build-Out by any contractor or subcontractor of such
Tenant (or any other Persons claiming through or under Tenant).

        16.3 RETAIL AND RESTAURANT LEASES.

        (a) From and after the date hereof and continuing until the Earn-Out
Date, Mall II Buyer and Developer shall be jointly responsible for the leasing

                                       46
<Page>

of retail and restaurant space in the Phase II Mall. Developer (prior to the
Closing Date) and Mall II Buyer (from and after the Closing Date until the
Earn-Out Date) shall cause Mall II LLC, as landlord, to enter into Leases for
retail stores and restaurants to be located in the Phase II Mall with tenants
jointly selected by Mall II Buyer and Developer and on terms mutually acceptable
to Mall II Buyer and Developer. Mall II Buyer and Developer shall lease space in
the Phase II Mall, including any retail carts or kiosks located in the Phase II
Mall, to tenants who are retail or restaurant tenants appropriate for and
consistent with, a quality and standard for the Phase II Mall and its aggregate
occupant mix that is not less than the quality and standard of the "Grand Canal
Shoppes at the Venetian" as of the date hereof. In addition, all Leases for
restaurants executed prior to the Earn-Out Date shall be entered into with
tenants operating "specialty 2-star" restaurants or better. The consent of both
of Mall II Buyer and Developer shall be necessary for the execution of any Lease
prior to the Earn-Out Date. Both parties will use commercially reasonable
efforts to include a 15% administrative fee and provisions for reimbursement of
a 3% management fee in all Leases.

        (b) From and after the date hereof and continuing until the Earn-Out
Date (and from and after the Earn-Out Date until the Final Date (as defined in
Section 20.3) to the extent the Recalculated Earn-Out (as defined in Section
20.3) would or might be affected), no Lease amendment that would or might affect
net operating income through the Earn-Out Date or termination agreement shall be
entered into unless approved by both Mall II Buyer and Developer, no monetary or
other material obligation in any Lease that accrues prior to the Earn-Out Date
shall be waived unless such waiver is approved by both Mall II Buyer and
Developer, and no Lease shall be terminated unless such termination is approved
by both Mall II Buyer and Developer. From and after the date hereof until the
Final Date, (i) if Developer requests that Mall II LLC conduct an audit of a
tenant to determine if such tenant, with respect to any period of time prior to
the Earn-Out Date, underpaid "percentage" or "overage" rent, Mall II Buyer shall
cause Mall II LLC to diligently conduct such audit "in-house" in accordance with
procedures reasonably agreed to by Mall II Buyer and Developer, and shall keep
Developer informed of the results of such audit and (ii) if any tenant exercises
its right to conduct an audit of Mall II LLC's "CAM" charges or other
recoverable expenses, Developer and Mall II Buyer shall, subject to compliance
with the applicable Lease provisions, jointly make all decisions in connection
therewith and in connection with any proposed settlement with such tenant
related thereto, and Mall II Buyer shall cause Mall II LLC to take actions
consistent with such decisions.

        (c) Prior to the Closing Date, any security deposit or other payment
received from Tenants ("TENANT PAYMENTS") shall be held by Mall II LLC or, if
Mall II LLC has not yet been formed, by Developer in a separate interest bearing
account. Promptly after the formation of Mall II LLC, Developer shall transfer
any Tenant Payments so held by Developer to an account of Mall II LLC. Prior to
the Closing, all Tenant Payments held by Developer or by Mall II LLC pursuant to
this Section 16.3 (c) shall be maintained in an interest-bearing account. At the
Closing, the Tenant Payments will remain the possession of Mall II LLC and there
shall be no adjustment made to the Closing Payment or any other payments due
under this Agreement in respect of such Tenant Payments.

                                       47
<Page>

        16.4 COMPLIANCE WITH GAMING LAWS BY TENANTS. Mall II Buyer acknowledges
that Developer and Affiliates of Developer conduct businesses that are or may be
subject to and exist because of privileged licenses issued by Gaming
Authorities. Therefore, not less than thirty (30) days prior to Mall II LLC
entering into any Lease (a "PROPOSED LEASE"), Mall II Buyer and Developer shall
cause the tenant under such Proposed Lease (the "PROPOSED TENANT"), if such
Proposed Tenant is a corporation, to disclose to Mall II Buyer and Developer the
names of all of its officers and directors. Unless it is a publicly traded
corporation on a national stock exchange, the Proposed Tenant shall disclose to
Mall II Buyer and Developer all direct and indirect ownership interests in the
Proposed Tenant and all lenders or sources of financing. If requested to do so
by Developer, Mall II Buyer shall require a Proposed Tenant to obtain any
license, qualification, clearance or the like which shall be requested or
required of any Proposed Tenant by any Gaming Authority or any regulatory
authority having jurisdiction over Developer or any Affiliate of Developer. If a
Proposed Tenant fails to satisfy such requirement or if Developer or any
Affiliate of Developer is directed not to involve itself in business with a
Proposed Tenant by any such authority, or if Developer shall in good faith
determine that a Proposed Tenant, or any of its officers, directors, employees,
agents, designees or representatives, or a partner, owner, member, or
shareholder, or any lender or financial participant (a) is or might be engaged
in, or is about to be engaged in, any activity or activities, or (b) was or is
involved in any relationship, either of which could or does jeopardize
Developer's business, reputation or such licenses, or those of its Affiliates,
or if any such license is threatened to be, or is, denied, curtailed, suspended
or revoked, then Mall II LLC, at Developer's direction, shall not enter into the
Proposed Lease with the Proposed Tenant. Any Lease entered into in violation of
this Section 16.4 shall be deemed null and void and of no force or effect. All
Leases shall include the provision set forth in SCHEDULE "19" attached hereto
and made a part hereof. To the extent any Lease shall not include the provision
set forth in SCHEDULE "19," such Lease shall be null and void and of no force or
effect. Developer and its successors and assigns shall be a third-party
beneficiaries of the provision described in SCHEDULE "19" (and the applicable
Leases shall so provide) and Developer and its successors and assigns shall have
the right to take all appropriate action to enforce such provision, including
initiating and prosecuting to completion eviction proceedings. The provisions of
this Section 16.4 shall survive until the Closing at which point the inclusion
of gaming provisions in the Leases or Proposed Leases shall be governed by the
Amended REA.

        16.5 COMPLIANCE WITH GAMING LAWS BY MALL II BUYER. Mall II Buyer
acknowledges that Developer and Affiliates of Developer conduct businesses that
are or may be subject to and exist because of privileged licenses issued by
Gaming Authorities. Mall II Buyer has disclosed to Developer the names of all of
its officers and directors on Part Two of SCHEDULE "10." Mall II Buyer has also
disclosed on SCHEDULE "10" all direct and indirect ownership interests in Mall
II Buyer (excluding (i) any holders of publicly traded shares of General Growth
Properties, Inc. or (ii) any limited partners of GGP Limited Partnership that
are Institutional Investors) and all lenders or sources of financing that are
not Institutional Investors. Mall II Buyer shall promptly notify Developer of
any occurrence which might make the information set forth on SCHEDULE "10"
incorrect or incomplete. If requested to do so by Developer, Mall II Buyer

                                       48
<Page>

shall obtain any license, qualification, clearance or the like which shall be
requested or required of Mall II Buyer by any Gaming Authority or any regulatory
authority having jurisdiction over Developer or any Affiliate of Developer. If
Mall II Buyer fails to satisfy such requirement or if Developer or any Affiliate
of Developer is directed not to involve itself in business with Mall II Buyer by
any such Gaming Authority, or if Developer shall in good faith determine that
Mall II Buyer, or any of its officers, directors, employees, agents, designees
or representatives, or a partner, owner, member, or shareholder, or any lender
or financial participant (a) is or might be engaged in, or is about to be
engaged in, any activity or activities, or (b) was or is involved in any
relationship, either of which could or does jeopardize Developer's business,
reputation or such licenses, or those of its Affiliates, or if any such license
is threatened to be, or is, denied, curtailed, suspended or revoked, then Mall
II Buyer, at Developer's direction, shall immediately (i) terminate any
relationship with the individual or entity which is the source of the problem or
(ii) cease the activity creating the problem. If Mall II Buyer does not comply
with item (i) or (ii) above, then Developer may require Mall II Buyer to
specifically perform such obligation (the parties recognizing that damages or
other remedies would be inadequate under the circumstances). The provisions of
this Section 16.5 shall survive until the Closing at which point Mall II Buyer's
compliance with the Gaming Authorities shall be governed by the Amended REA.

        16.6 REMAKING OF WARRANTIES; SURVIVAL. All of Mall II Buyer's
representations and warranties set forth in this Article 16 shall be deemed to
have been remade on and as of the Closing Date, and Mall II Buyer shall deliver
a certificate at Closing recertifying such representations and warranties. Such
representations and warranties, as remade, shall survive the Closing without
limitation as to time. The covenants made by Mall II Buyer in Article 4, Article
5 and this Article 16 shall survive the Closing without limitation as to time.

                                   ARTICLE 17

                      TRANSACTION EXPENSES; TITLE INSURANCE

        17.1 FEES AND COSTS OF ATTORNEYS AND CONSULTANTS. Except as otherwise
provided herein, each party shall pay the Fees and Costs of its own attorneys
and Consultants in connection with this Agreement and the transactions
contemplated hereunder.

        17.2 TITLE PREMIUMS. Mall II Buyer shall pay the costs for the issuance
of the Title Insurance Commitment and the insurance effected pursuant thereto.

        17.3 REAL PROPERTY TRANSFER TAXES. Developer shall pay on or prior to
the Closing Date all State and County real property transfer taxes (if any)
payable in connection with the conveyance of the Membership Interests to Mall II
Buyer.

        17.4 APPORTIONMENTS. Real property taxes, water and sewage charges and
utilities and fuel charges to be paid with respect to the Phase II Mall shall be
apportioned at the Closing, with Developer to be responsible for Mall II LLC's

                                       49
<Page>

obligations in regard thereto through the day preceding the Closing Date and
Mall II Buyer to be responsible for Mall II LLC's obligations in regard thereto
for the period including and following the Closing Date.

        17.5 PAYMENTS UNDER AMENDED REA. Mall II Buyer's obligation to cause
Mall II LLC to pay any and all charges apportioned to Mall II LLC under the
terms of the Amended REA will commence as of the Closing Date.

        17.6 The provisions of this Article 17 shall survive the Closing.

                                   ARTICLE 18

                       DAMAGE OR DESTRUCTION; CONDEMNATION

        18.1 MAJOR EVENT. As used herein, "MAJOR EVENT" means the giving of
official notice by a Government Authority of a condemnation or taking under the
power of eminent domain of any part of the Building or the Phase II Land (a
"CONDEMNATION"), which Condemnation involves all or a substantial portion of the
Phase II Land or the Building so that Developer would be unable to satisfy the
conditions set forth in Article 10.

        18.2 TERMINATION AFTER MAJOR EVENT. Developer shall give notice to Mall
II Buyer of the occurrence of a Major Event, in which event, this Agreement
shall terminate thirty (30) days after the giving of such notice. If this
Agreement is terminated as aforesaid, neither Mall II Buyer nor Developer shall
have any further rights or obligations to the other hereunder, except those that
survive termination.

        18.3 RESTORATION AFTER CASUALTY OR CONDEMNATION. If (a) (after Developer
commences construction) a fire or other casualty occurs to the Mall Improvements
or (b) a Condemnation that is not a Major Event shall occur, Developer shall
proceed, at Developer's expense, to reconstruct or restore the damaged or taken
portions of the Mall Improvements or the Phase II Land and thereafter will
complete restoration and reconstruction as promptly as possible; and the Closing
Date or the Outside Substantial Completion Date and, if the same has been agreed
to, the Opening Date shall be adjourned automatically, taking into account all
relevant facts and circumstances, to allow for such restoration or
reconstruction. There shall be no adjustment made to the Closing Payment or the
Earn-Out Payment in regard of such reconstruction.

        18.4 WAIVER. This Article constitutes an express waiver by the parties
of any law apportioning risk of loss under contracts for the sale or purchase of
real property.

        18.5 INSURANCE PROCEEDS. All proceeds of insurance and/or condemnation
payable by reason of a Major Event or other casualty or condemnation affecting
the Building before the Closing shall belong to Developer.

                                       50

<Page>
                                   ARTICLE 19

                            REMOVAL OF TITLE DEFECTS

        19.1 TITLE DEFECT. "TITLE DEFECT" means any Encumbrance recorded
against, or otherwise affecting, the Phase II Mall which is NOT a Permitted
Encumbrance. ---

        19.2 NOTICE AND REMOVAL OF TITLE DEFECTS. On or before the Closing Date,
Mall II Buyer shall promptly give Developer notice of any Title Defect of which
it becomes aware. If Mall II Buyer gives notice to Developer of any such Title
Defect, Developer may adjourn the Closing for a period or periods not exceeding
forty-five (45) days in the aggregate in order to remove the Title Defect(s)
specified in Mall II Buyer's notice. Upon the expiration of such period(s) (or
on the Closing Date if sooner and if Developer does not so adjourn the Closing),
if Developer is unable (subject to Article 21 hereof) or is not required to
satisfy the conditions in Section 10.1(d) of this Agreement, then provided that
the Title Defect does not prevent the operation by Mall II LLC of a mall in the
Mall Space, Mall II Buyer shall accept such title as Developer is then able to
provide and the Closing Payment shall be reduced in an amount equal to the
amount by which such Title Defect(s) reduce the value of the Phase II Mall, as
such reduction shall be determined by the Developer and Mall II Buyer after good
faith consultations. If Developer and Mall II Buyer are unable to agree on the
amount of the reduction in the Closing Payment, an Independent Expert shall
determine the amount pursuant to Article 9.

        19.3 DISCHARGE OF MORTGAGES AND LIENS. Developer agrees, without further
notice from Mall II Buyer, to pay and discharge at the Closing all Mortgages
against the Phase II Mall, and to remove and discharge of record, by payment,
bonding or otherwise, other liens of record against the Phase II Mall which may
be satisfied by payment of money only and which are not Permitted Encumbrances.
Except as specified in this Section, Developer shall have no obligation to
remove or cure Encumbrances.

        19.4 TITLE AFFIDAVITS. At or before the Closing, Developer shall execute
and deliver to the Title Insurer such affidavits as are customarily given by a
seller to induce the Title Insurer to issue the title policy described in
Section 10.1(d) including, without limitation, a non-imputation endorsement
thereto.

        19.5 JUDGMENT SEARCHES. If a search of the title discloses judgments,
bankruptcies or other returns against other Persons having names the same as or
similar to those of Developer or Mall II LLC, Developer will establish to the
satisfaction of Mall II Buyer and the Title Insurer that such judgments,
bankruptcies or other returns are not against Developer or Mall II LLC.

                                       51
<Page>

                                   ARTICLE 20

                           CLOSING AND OTHER PAYMENTS

        20.1 Upon and subject to the terms and conditions of this Agreement, the
Developer agrees to sell and assign the Membership Interests to Mall II Buyer
and Mall II Buyer agrees to purchase the Membership Interests from the
Developer, to assume the obligations in respect thereof accruing from and after
the Closing Date and to pay to Developer the Closing Payments, the Adjustments
Payments, the Earn-Out Payment, the Recalculated Earn-Out and any other payment
due pursuant to the terms of this Agreement.

        20.2 PAYMENTS. Developer agrees to construct the Phase II Mall
substantially in accordance with the Initial Plans (before the Final
Construction Drawings and Specs are agreed to by Mall II Buyer and Developer)
and Final Construction Drawings and Specs (once the same are agreed to by Mall
II Buyer and Developer) and the terms of this Agreement, and, in consideration
therefor, Mall II Buyer shall make the following payments to Developer:

        (a) CLOSING PAYMENT. At the Closing, Mall II Buyer shall pay to
Developer by wire transfer of immediately available federal funds to an account
designated by Developer an amount (the "CLOSING Payment") equal to the greater
of (i) two hundred and fifty million dollars ($250,000,000) and (ii) the
projected net operating income divided by the Cap Rate. As used in this
Agreement, the "CAP RATE" shall mean (A) .06 for every dollar of net operating
income up to thirty-eight million dollars ($38,000,000) and (B) (without
modifying or nullifying clause (A)) .08 for every dollar of net operating income
including and above thirty-eight million dollars ($38,000,000). If, despite good
faith efforts by Developer and Mall II Buyer to arrive at an appropriate amount
of the Closing Payment, there is a disagreement over the amount of the Closing
Payment, the parties shall agree to close despite such disagreement and Mall II
Buyer shall pay to Developer the entire undisputed portion of the Closing
Payment subject to the following sentence. Upon resolution by Mall II Buyer and
Developer (or by the Independent Expert) of the disputed amount, Mall II Buyer
shall also pay to Developer interest at the Interest Rate on the amount
calculated pursuant to this Section 20.2(a), to the extent unpaid, for the
period from the Closing Date to the date on which the Closing Payment is made to
Developer.

        (b) ADJUSTMENT PAYMENTS.

        (1) On the Business Day immediately preceding each of the six (6) month
anniversary, the twelve (12) month anniversary, the eighteen (18) month
anniversary and the twenty-four (24) month anniversary of the Closing Date (each
an "INTERIM PAYMENT DATE" and, collectively, the "INTERIM PAYMENT DATES"), Mall
II Buyer shall pay to Developer by wire transfer of immediately available
federal funds to an account designated by Developer an amount (each an
"ADJUSTMENT PAYMENT" and, collectively, the "ADJUSTMENT PAYMENTS") equal to the
positive difference, if any, between

                                       52
<Page>

(i) the net operating income divided by the Cap Rate and (ii) (A) the sum of the
Closing Payment and the net aggregate amount of any Adjustment Payments made to
Developer, if any, made on previous Interim Payment Dates MINUS (B) the amount
of any free rent granted to Tenants under any Leases included in the calculation
of net operating income as of such Interim Payment Date for the period from the
immediately prior Interim Payment Date (or the Closing Date, for the first
Adjustment Payment) up to and including such Interim Payment Date. If, despite
good faith efforts by Developer and Mall II Buyer to arrive at an appropriate
amount of any Adjustment Payment, there is a disagreement over the amount of
such Adjustment Payment from Mall II Buyer to Developer, Mall II Buyer shall pay
to Developer the entire undisputed portion of the Adjustment Payment, if any,
subject to the following sentence. Upon resolution by Mall II Buyer and
Developer (or by the Independent Expert) of the disputed amount, Mall II Buyer
shall also pay to Developer, as part of each Adjustment Payment, interest at the
Interest Rate on the amount calculated pursuant to this Section 20.2(b), to the
extent unpaid, for the period from the Interim Payment Date to the date on which
the applicable Adjustment Payment is made to Developer.

        (2) In the event that, on any Interim Payment Date, the amount set forth
in clause (ii) is greater than the amount set forth clause (i) of Section
20.2(b)(1), Developer shall pay the amount of such difference to Mall II Buyer
by wire transfer of immediately available federal funds to an account designated
by Mall II Buyer. If, despite good faith efforts by Developer and Mall II Buyer
to arrive at an appropriate amount of any Adjustment Payment from Developer to
Mall II Buyer, there is a disagreement over the amount of such Adjustment
Payment, Developer shall pay to Mall II Buyer the entire undisputed portion of
the Adjustment Payment, if any, subject to the following sentence. Upon
resolution by Mall II Buyer and Developer (or by the Independent Expert) of the
disputed amount, Developer shall also pay to Mall II Buyer, as part of each such
payment, interest at the Interest Rate on the amount calculated pursuant to the
preceding sentence, to the extent unpaid, for the period from the Interim
Payment Date to the date on which such payment is made to Mall II Buyer.
Notwithstanding the foregoing, Developer shall have no obligation to make any
payments pursuant to this Section 20.2(b)(2) which would have the effect of
reducing the net aggregate amount received by Developer from Mall II Buyer
pursuant to the Closing Payments and the Adjustment Payments (excluding amounts
received that constitute interest on amounts not paid on the date due) below two
hundred and fifty million dollars ($250,000,000).

        (c) EARN-OUT PAYMENT.

        (1) On the date that is thirty (30) months after the Closing Date (the
"EARN-OUT DATE"), Mall II Buyer shall pay to Developer by wire transfer of
immediately available federal funds to an account designated by Developer, an
amount (with interest as provided below, the "EARN-OUT PAYMENT") equal to the
positive difference, if any, between (i) the net operating income divided by the
Cap Rate and (ii) (A) the sum of the Closing Payment and the net aggregate
amount of all Adjustment Payments made to Developer, if any, MINUS (B) the
amount of any free rent granted to Tenants under any Leases included in the
calculation of net operating income as of the

                                       53
<Page>

Earn-Out Date for the period from the final Interim Payment Date up to and
including the Earn-Out Date. If, despite good faith efforts by Developer and
Mall II Buyer to arrive at an appropriate amount of the Earn-Out Payment from
Mall II Buyer to Developer, there is a disagreement over the amount of the
Earn-Out Payment, Mall II Buyer shall pay to Developer the entire undisputed
portion of the Earn-Out Payment, if any, that the parties can agree is payable
from Mall II Buyer to Developer, subject to the following sentence. Upon
resolution by Mall II Buyer and Developer (or by the Independent Expert) of the
disputed amount, Mall II Buyer shall also pay to Developer, as part of the
Earn-Out Payment, interest at the Interest Rate on the amount calculated
pursuant to this Section 20.2(c), to the extent unpaid, for the period from the
Earn-Out Date to the date on which the Earn-Out Payment is made to Developer. In
the event that a Market Disruption Event shall occur, then Developer shall have
the right, but not the obligation, to extend the Earn-Out Date up to one day for
each day that such Market Disruption Event shall continue. A "MARKET DISRUPTION
EVENT" shall have been deemed to have occurred on the first day of the month
(the "INITIAL MARKET DISRUPTION DATE") when, in response to a specific event or
series of events (for example a contagious disease outbreak or terrorist event
which results in decreased numbers of travelers), the total number of airline
passengers enplaning and deplaning at McCarran International Airport, Las Vegas,
Nevada, in any given month, as reported by the Las Vegas Convention and Visitors
Authority in either its "MONTHLY EXECUTIVE SUMMARY" or its annual "YEAR-TO-DATE
EXECUTIVE SUMMARY" (or some other verifiable source of such similar statistical
information) ("MCCARRAN PASSENGERS") decreases more than twenty percent (20%) as
compared to the same month in the prior year. Such Market Disruption Event shall
be deemed to continue until the last day of the month in which the number of
McCarran Passengers for such month is equal to or greater than the number of
McCarran Passengers in the same month in the prior year, but in no event shall
the Earn-Out Date be delayed for longer than one (1) year due to such Market
Disruption Event.

        (2) In the event that, on the Earn-Out Date, the amount set forth in
clause (ii) is greater than the amount set forth in clause (i) of Section
20.2(c)(1), Developer shall pay the amount of such difference to Mall II Buyer
by wire transfer of immediately available federal funds to an account designated
by Mall II Buyer. If, despite good faith efforts by Developer and Mall II Buyer
to arrive at an appropriate amount of the Earn-Out Payment from Developer to
Mall II Buyer, there is a disagreement over the amount of the Earn-Out Payment,
Developer shall pay to Mall II Buyer the entire undisputed portion of the
Earn-Out Payment, if any, that the parties can agree is due from Developer to
Mall II Buyer, subject to the following sentence. Upon resolution by Mall II
Buyer and Developer (or by the Independent Expert) of the disputed amount,
Developer shall also pay to Mall II Buyer, as part of each such payment,
interest at the Interest Rate on the amount calculated pursuant to the preceding
sentence, to the extent unpaid, for the period from the Earn-Out Date to the
date on which such payment is made to Mall II Buyer. Notwithstanding the
foregoing, Developer shall have no obligation to make any payments pursuant to
this Section 20.2(c)(2) which would have the effect of reducing the net
aggregate amount received by Developer from Mall II Buyer pursuant to the
Closing Payment, all Adjustment Payments and the Earn-Out Payment (excluding
amounts received that constitute interest on amounts not paid on the date due)
below two hundred and fifty million dollars ($250,000,000).

                                       54
<Page>

        (d) OTHER. Any other payment required by the terms of this Agreement.

        20.3 RECALCULATED EARN-OUT. On the eighteen-month anniversary of the
Earn-Out Date (the "FINAL Date"), each of the parties shall identify by notice
to the other any items that should have been appropriately included as operating
income or operating expenses as of the Earn-Out Date had the parties been aware
of such item (by way of example, and without limitation, any adjustment made
pursuant to a Tenant audit) and recalculate the net operating income and the
Earn-Out Payment taking those items into account (the "RECALCULATED EARN-OUT").
On the Final Date, Mall II Buyer shall pay to Developer the positive difference,
if any, between the Recalculated Earn-Out less the Earn-Out Payment actually
made on the Earn-Out Date. If the Recalculated Earn-Out is less the Earn-Out
Payment, Developer shall pay to Mall II Buyer the amount of such difference. If,
despite good faith efforts by Developer and Mall II Buyer to arrive at an
appropriate amount of the Recalculated Earn-Out from Mall II Buyer to Developer
or from Developer to Mall II Buyer, there is a disagreement over the amount of
the Recalculated Earn-Out, Developer shall pay to Mall II Buyer the entire
undisputed portion of the Recalculated Earn-Out, if any, that the parties can
agree is due from Developer to Mall II Buyer, or Mall II Buyer shall pay to
Developer the entire undisputed portion of the Recalculated Earn-Out, if any,
that the parties can agree is due from Mall II Buyer to Developer, subject to
the following sentence. Upon resolution by Mall II Buyer and Developer (or by
the Independent Expert) of the disputed amount, the party determined to owe
money to the other shall pay to the other, as part of each such payment,
interest at the Interest Rate on the amount calculated pursuant to the preceding
sentence, to the extent unpaid, for the period from the Earn-Out Date to the
date on which such payment is made to the other party. Notwithstanding the
foregoing, Developer shall have no obligation to make any payments pursuant to
this Section 20.3 which would have the effect of reducing the net aggregate
amount received by Developer from Mall II Buyer pursuant to the Closing Payment,
all Adjustment Payments, the Earn-Out Payment and the Recalculated Earn-Out
(excluding amounts received that constitute interest on amounts not paid on the
date due) below two hundred and fifty million dollars ($250,000,000).

        20.4 INDEPENDENT EXPERT. Any dispute in the calculation of the Closing
Payment, the Adjustment Payments, the Earn-Out Payment or the Recalculated
Earn-Out shall be resolved by an Independent Expert in accordance with Article 9
of this Agreement.

        20.5 AUDITS. Developer or its designee shall have the right, from time
to time following the Closing, until 90 days after receipt by Developer of the
Recalculated Earn-Out, at the Developer's expense during business hours and on
reasonable prior notice to Mall II LLC, to examine and audit so much of the
books and records of Mall II Buyer or Mall II LLC as relate to the calculation
of the Closing Payment, any of the Interim Payment, the Earn-Out Payment or the
Recalculated Earn-Out to verify the operating income and operating expenses
reported by Mall II Owner or Mall II LLC (or any successor of Mall II LLC) in
connection with such payments.

                                       55
<Page>

                                   ARTICLE 21

                              PRE-CLOSING REMEDIES

        21.1 MALL II BUYER'S REMEDIES.

        (a) If Developer has failed to achieve Substantial Completion by the
Outside Substantial Completion Date, Mall II Buyer's remedies shall be as set
forth in Section 7.1.

        (b) If Substantial Completion has occurred, but any other condition to
Mall II Buyer's obligation to close under this Agreement as set forth in Section
10.1 has not been satisfied, then Mall II Buyer shall give notice to Developer
setting forth the conditions that have not been satisfied. Developer shall have
a reasonable period of time, not to exceed one hundred twenty days (and in no
event after the Outside Substantial Completion Date) to satisfy such conditions.
If (1) Developer shall fail to satisfy such conditions within such cure period,
(2) the conditions set forth in this Agreement to Developer's obligation to
close have been satisfied and (3) Mall II Buyer is not otherwise in default of
its obligations under this Agreement, then:

        (i) Mall II Buyer shall be entitled to bring a Legal Proceeding for
specific performance of Developer's obligations under this Agreement, and, if
specific performance is available as a remedy to Mall II Buyer, it shall be the
sole and exclusive remedy for Developer's default. Mall II Buyer may recover
from Developer (which Developer shall pay upon demand) all Fees and Costs paid
or incurred by Mall II Buyer to secure specific performance under this
Agreement.

        (ii) If Mall II Buyer is unable to obtain specific performance of
Developer's obligations under this Agreement, Mall II Buyer shall be entitled to
terminate this Agreement, in which event Developer shall pay to Mall II Buyer
upon demand the Buyer Liquidated Damages Amount as liquidated damages.

        (iii) If Developer has breached this Agreement by constructing a project
on the Phase II Land and in the Leasehold Airspace that does not include a
substantial mall component or by selling either the Phase II Mall or the
Membership Interests to a third party. and Mall II Buyer is unable to obtain
specific performance of Developer's obligations under this Agreement, Mall II
Buyer shall be entitled to terminate this Agreement and, at Mall II Buyer's
election, either (A) require Developer to pay to Mall II Buyer upon demand the
Buyer Liquidated Damages Amount as liquidated damages or (B) bring a Legal
Proceeding against Developer to recover Mall II Buyer's actual damages.

        (c) In the event that Mall II Buyer exercises its remedy to receive
Buyer Liquidated Damages under Section 7.1 or Section 21.1(b)(iii) and Developer
shall, subsequent to the exercise of such remedy, achieve Substantial Completion
of the Mall Improvements or a substantial retail component on the Phase II Land
or in the Leasehold Airspace, Mall II Buyer shall have the right to consummate
the

                                       56
<Page>

purchase of the Membership Interests (if such improvements have been conveyed to
Mall II LLC) or the purchase of such improvements and the fee and leasehold
interests associated therewith (if such improvements have not been conveyed to
Mall II LLC) within thirty (30) days following notice from Developer to Mall II
Buyer that Substantial Completion has occurred on the terms of this Agreement.
If Mall II Buyer shall exercise such right, Mall II Buyer shall return the Buyer
Liquidated Damages Amount to Developer and shall not receive a credit for such
amounts against the purchase price for the Membership Interests. This provision
shall survive the termination of this Agreement.

        21.2 DEVELOPER'S REMEDIES. If all conditions to Mall II Buyer's
obligations to close under this Agreement are satisfied and Mall II Buyer shall
fail to close title hereunder and deliver the Closing Payment and the Closing
Instruments on the Closing Date, Developer may exercise any of the following
remedies:

        (a) Developer shall be entitled to bring a Legal Proceeding for specific
performance of Mall II Buyer's obligations under this Agreement. Developer may
recover from Mall II Buyer (which Mall II Buyer shall pay upon demand) all Fees
and Costs paid or incurred by Developer to secure specific performance under
this Agreement; or

        (b) As Mall II Buyer and Developer agree that it would be impracticable
and extremely difficult to ascertain the actual damages to Developer as a result
of the failure of Mall II Buyer to deliver the Closing Payment and the Closing
Instruments on the Closing Date and that a reasonable estimate of the damages
which Developer would incur as a result of such failure is the amount of one
hundred million dollars ($100,000,000) (the "DEVELOPER LIQUIDATED DAMAGES
AMOUNT"), Developer may terminate this Agreement, in which event upon
Developer's demand, Mall II Buyer shall pay to Developer the Developer
Liquidated Damages Amount as liquidated damages for Mall II Buyer's default; or

        (c) As further provided in the Amended REA, Developer may terminate this
agreement and, within sixty (60) days after termination of this Agreement, elect
to purchase the limited liability company membership interests of Mall I LLC
owned by Mall I Buyer for a purchase price (the "MALL I CALL PRICE") equal to
(i) the LESSER of (y) the purchase price paid for the limited liability company
membership interests in Mall I LLC by Mall I Buyer pursuant to the Phase I Mall
Sale Agreement and (z) the fair market value of the limited liability company
membership interests in Mall I LLC as of the date that Developer has achieved
Substantial Completion less (ii) the Developer Liquidated Damages Amount; or

        (d) If Developer exercises the remedy set forth in Section 21.2(c) above
and if the Mall I Call Price is less than the then-outstanding indebtedness
secured by the Phase I Mall or the interest in Mall I LLC, Developer may
purchase the limited liability company interests in Grand Canal Shops II LLC for
the amount of such indebtedness (whether by paying or assuming the same) and
bring a Legal Proceeding

                                       57
<Page>

against Mall II Buyer for the difference between the amount so paid or assumed
(including any costs incurred in connection therewith) and the Mall I Call
Price.

        21.3 DEFAULT UNDER PHASE I MALL SALE AGREEMENT. In the event that the
transaction described in the Phase I Mall Sale Agreement is not consummated as
contemplated by such agreement, this Agreement shall automatically terminate. If
the transaction set forth in the Phase I Mall Sale Agreement is not consummated
due to a default by either Grand Canal Shops Mall MM Subsidiary, Inc. or Grand
Canal Shops Mall Subsidiary, LLC under the Phase I Mall Sale Agreement, upon
Mall II Buyer's demand, Developer shall pay to Mall II Buyer the Mall II Buyer
Liquidated Damages Amount as liquidated damages for the termination of this
Agreement. If the transaction set forth in the Phase I Mall Sale Agreement is
not consummated due to a default by Mall I Buyer under the Phase I Mall Sale
Agreement, upon Developer's demand, Mall II Buyer shall pay to Developer the
Developer Liquidated Damages Amount as liquidated damages for the termination of
this Agreement.

                                   ARTICLE 22

                              POST-CLOSING REMEDIES

        After the Closing Date, except for (and excluding) those breaches of
obligations or other matters for which this Agreement provides specific and
exclusive remedies to a particular party (including, without limitation, Section
21.2(c)), each party retains, and may pursue, all rights available at law or in
equity by reason of the other party's failure to keep or perform such other
party's agreements or obligations under this Agreement pertaining to the period
after the Closing Date. The provisions of this Article 22 shall survive the
Closing.

                                   ARTICLE 23

                                     NOTICES

All notices, consents or other communications under this Agreement must be in
writing and addressed to each party at its respective Notice Address set forth
on SCHEDULE "8" attached hereto and made a part hereof (or at any other address
which the respective parties may designate by notice given to the other party
from time to time). Any notice required by this Agreement to be given or made
within a specified period of time, on or before a date certain, shall be deemed
given or made if sent by hand, by fax with confirmed answerback received, or by
registered or certified mail (return receipt requested and postage and registry
fees prepaid). Delivery "BY HAND" shall include delivery by commercial express
or courier service. A notice sent by registered or certified mail shall be
deemed given on the date of receipt (or attempted delivery if refused) indicated
on the return receipt. All other notices shall be deemed given when actually
received. A notice may be given by a party or by its legal counsel.

                                       58
<Page>

                                   ARTICLE 24

                                  MISCELLANEOUS

        24.1 FURTHER ASSURANCES. Each of the parties shall take such actions and
sign and deliver such other instruments and documents as may be reasonable,
necessary or appropriate to effectuate the transactions contemplated under this
Agreement; provided, however, that the taking of such acts or the execution of
such documents will not result in material cost or liability to the respective
party which is not otherwise required under this Agreement. Without limiting the
foregoing, Developer shall, upon the request of Mall II Buyer from time to time,
provide signed representation letters with respect to revenues and expenses of
Mall II LLC for the period prior to Closing to enable Mall II Buyer's
accountants to render an opinion on Mall II Buyer's or any of its Affiliates'
financial statements, provided that the same shall be at no third party (out of
pocket) cost to Developer and Mall II Buyer shall reimburse Developer for all
reasonable cost and expenses incurred by Developer within fifteen (15) days
written notice of same.

        24.2 GOVERNING LAW. This Agreement shall be governed and construed in
accordance with the laws of the State (without regard to principles of conflicts
of law).

        24.3 AMENDMENT. This Agreement shall not be modified, waived, or amended
except by written agreement executed by all the parties.

        24.4 INTEGRATION. This Agreement, together with the Schedules and
Exhibits hereto, and any other binder of documents, agreements or instruments
which is specifically stated to form a part of this Agreement or to relate
thereto, constitute(s) the entire agreement between the parties with respect to
the subject matter hereof and supersedes all other prior agreements and
understandings of the parties relating thereto.

        24.5 NO WAIVER. Except as expressly provided in this Agreement, no delay
on the part of any party hereto in exercising any right, power or privilege
hereunder shall operate as a waiver thereof or as a waiver of any other right,
power or privilege hereunder, nor shall any single or partial exercise of any
right, power or privilege hereunder preclude any other or further exercise
hereunder. Except as otherwise provided in this Agreement, the rights and
remedies of each party under this Agreement are cumulative and are not exclusive
of any rights or remedies which the party may otherwise have at law or in
equity.

        24.6 COUNTERPARTS. This Agreement may be executed (a) in counterparts, a
complete set of which together shall constitute an original and (b) in
duplicates, each of which shall constitute an original. Copies of this Agreement
showing the signatures of the respective parties, whether produced by
photographic, facsimile, digital, computer, or other reproduction, may be used
for all purposes as originals.

                                       59
<Page>

        24.7 SUCCESSORS AND ASSIGNS. This Agreement (and all terms thereof,
whether so expressed or not), shall be binding upon the respective permitted
successors, assigns and legal representatives of the parties and shall inure to
the benefit of and be enforceable by the parties and their respective permitted
successors, assigns and legal representatives.

        24.8 EXHIBITS AND SCHEDULES. The Exhibits and Schedules attached hereto
or subsequently incorporated herein are (and shall be deemed) parts of this
Agreement. The headings of this Agreement are for purposes of reference only and
shall not limit or otherwise affect the meaning hereof.

        24.9 ASSIGNMENT RESTRICTIONS. Subject to the other provisions of this
Section 24.9, neither Mall II Buyer nor Developer may assign this Agreement, or
any of its rights or obligations herein or hereunder, without the prior written
consent of the other, except an assignment as collateral security to secure a
loan or an assignment made in connection with a foreclosure or deed-in-lieu of
foreclosure of such loan (which are hereby expressly permitted hereunder). Any
attempted assignments in violation of this Section shall be null and void.
Notwithstanding the foregoing, Mall II Buyer shall have the right to assign this
Agreement or its rights hereunder (without the consent of Developer), in whole
or in part, to any Affiliate of Mall II Buyer (i) provided that such Affiliate
is not a Competitor of Developer and (ii) such assignment would not, in the good
faith judgment of Developer, jeopardize any of Developer's or Developer's
Affiliates Gaming Licenses. Any attempted assignments in violation of this
Section shall be null and void. Mall II Buyer shall not be released from any of
its obligations pursuant to this Agreement by virtue of such assignment.

        24.10 AUTHORIZATION. The signature of any one of a party's Authorized
Representatives, acting alone, shall constitute the duly authorized, valid and
binding act of the party for whom the respective person is the Authorized
Representative. A party may change (or add) Authorized Representative(s) at any
time by notice to the other party; and each party shall be entitled to rely upon
the written certificate or consent of any person designated by the other party
as an Authorized Representative.

        24.11 JURISDICTION. Each party irrevocably submits to the jurisdiction
of the courts of (and service of process in) the State and agrees that any
action or proceeding arising out of or relating to this Agreement may be brought
and/or defended in such courts.

        24.12 SEVERABILITY. If any term, covenant, condition or provision of
this Agreement is determined by a final judgment to be invalid or unenforceable,
the remaining terms, covenants, conditions and provisions of this Agreement
shall not be affected thereby; and each other term, covenant, condition and
provision of this Agreement shall be valid and enforceable to the fullest extent
permitted by law.

                                       60
<Page>

        24.13 NO THIRD PERSONS. Nothing in this Agreement, express or implied,
is intended: (a) to confer on any Person, other than the parties hereto, any
rights, obligations, liabilities, or remedies; (b) to constitute Mall II Buyer
as a partner or co-venturer of Developer; or (c) to waive any claim or right of
any party hereto against any Person who is not a party hereto.

        24.14 CONSTRUCTION. This Agreement shall be construed without regard to
any presumption requiring construction against the party drafting this
Agreement.

        24.15 BROKERS. Developer and Mall II Buyer each represent and warrant to
the other that such party has not had any conversations or dealings with any
broker, finder, or similar party in connection with the transactions
contemplated hereby other than Goldman Sachs. Each party shall indemnify the
other from and against any and all claims, liabilities, losses, damages, costs,
or expenses (including Fees and Costs) arising out of a breach of the foregoing
representation by such party. This Section shall survive the Closing or
termination of this Agreement.

        24.16 ATTORNEYS' FEES. In event of any Legal Proceeding between or among
Mall II Buyer and Developer concerning this Agreement, the substantially
prevailing party shall be entitled to reimbursement from the other party for the
Fees and Costs of such proceeding incurred by the prevailing party.

        24.17 RULE AGAINST PERPETUITIES. If this Agreement or any covenants or
provisions herein would otherwise be unlawful, void or voidable for violation of
the Rule against Perpetuities, then the same shall continue until the earlier of
(a) January 1, 2030 and (b) twenty-one (21) years after the death of the
survivor of the descendants of the former President of the United States, George
H.W. Bush, living on the date of this Agreement.

        24.18 RECORDATION. The parties agree that this Agreement shall not be
recorded.

        24.19 CONFIDENTIALITY.

        (a) Each of the Parties hereto agrees that, except as required by law
(including securities laws, rules and regulations), each will treat as
confidential the terms of this Agreement and the transaction contemplated herein
and that prior to Closing neither will issue a press release, advertisement or
other public communication with respect to this Agreement or relating to the
transaction contemplated herein without the prior approval of the other party.
In addition, Mall II Buyer agrees that it will treat as confidential all
non-public information relating to the Venetian Casino Resort and the Palazzo
Casino Resort and all components thereof furnished to Mall II Buyer by or on
behalf of Developer and that it will not disclose any such information to other
persons or entities except for its attorneys, accountants and consultants, if
any, its lenders, the Title Insurer, its insurance companies and insurance
brokers, its partners or investors, if any, or as may be compelled or required
by law (including securities laws, rules and regulations).

                                       61
<Page>

If this Agreement is terminated or the Closing does not otherwise occur, Mall II
Buyer shall return to Developer all materials with respect to the Venetian
Casino Resort and the Palazzo Casino Resort and all components thereof furnished
to it by or at the behest of Developer and shall destroy all copies thereof and
notes relating thereto and certify to the Developer in writing that it has done
so. The preceding provisions of this Section 24.19 shall survive any termination
of this Agreement. On the Closing Date, the parties shall either issue a joint
press release reasonably satisfactory to each or, if each issues its own press
release, each such release must be reasonably satisfactory to the other.

        (b) Each of the parties hereto agrees that, except as required by law
(including securities laws, rules and regulations), it will treat as
confidential and not disclose the terms of this Agreement, including, without
limitation, the methods of calculating net operating income to any Tenants or
potential Tenants.

        24.20 LEASEHOLD SPACE. At the option of the Developer, the Leasehold
Space may be conveyed to Mall II Buyer as a fee interest rather than a leasehold
interest, in which event the closing deliveries of Developer will be modified
accordingly. All references herein to such leasehold interest shall be deemed
revised, as appropriate, to reflect such transfer of a fee interest.

                    [Signatures begin on the following page.]

                                       62
<Page>

        In witness whereof, Developer and Mall II Buyer have executed this
Agreement as of the date first above written.

               LIDO CASINO RESORT, LLC

               By:  Lido Casino Resort Holding Company, LLC

                    By:  Lido Intermediate Holding Company, LLC

                         By:  Venetian Casino Resort, LLC

                              By:   Las Vegas Sands, Inc.

                                    By:  /S/ ROBERT G. GOLDSTEIN
                                         -----------------------
                                         Name: Robert G. Goldstein
                                         Title: Senior Vice President

                  [Signatures continue on the following page.]

<Page>

                    GGP LIMITED PARTNERSHIP

                         By:  General Growth Properties, Inc.

                                         By:  /S/ JOEL BAYER
                                              Name:  Joel Bayer
                                              Title:    Senior Vice President

<Page>

                             SCHEDULES AND EXHIBITS

<Table>

<S>                       <C>
Schedule "1"        -      Phase II Land
Schedule "2"        -      Leasehold Airspace
Schedule "3"        -      Phase IA Airspace
Schedule "4"        -      Continuing Service Contracts
Schedule "5"        -      Permitted Encumbrances
Schedule "6"        -      Consents and Exceptions to Representations of the Parties
Schedule "7"        -      Miscellaneous Closing Deliveries
Schedule "8"        -      Authorized Representatives; Notice Addresses
Schedule "9"        -      Construction Safety & Health Manual
Schedule "10"       -      Organizational Representations of Developer and Mall II Buyer
Schedule "11"       -      Definition of Substantial Completion
Schedule "12"       -      REA
Schedule "13"       -      Mall II Buyer Legal Rates
Schedule "14"       -      Tenant Handbook
Schedule "15"       -      Cost Sharing Allocations
Schedule "16"       -      Master Lease Agreement
Schedule "17"       -      Intentionally Omitted
Schedule "18"       -      Leases
Schedule "19"       -      Gaming Provisions
Schedule "20"       -      Work Continuation Agreement

Exhibit A           -      Standards Document attaching Leasing Plans and Character Sketches
Exhibit B           -      Developer's Representation Certificate

</Table>

<Page>

                                  SCHEDULE "1"

                                  PHASE II LAND

                              Schedule "1" - Page 1

<Page>

                                  SCHEDULE "2"

                               LEASEHOLD AIRSPACE

                              Schedule "2" - Page 1

<Page>

                                  SCHEDULE "3"

                                PHASE IA AIRSPACE

                              Schedule "3" - Page 1

<Page>

                                  SCHEDULE "4"

                          CONTINUING SERVICE CONTRACTS

        1. An Energy Services Agreement with Sempra that conforms with the
requirements set forth in the REA.

        2. All public utility supply and distribution services, water, sewer and
electricity provided by such entities as Nevada Power, Las Vegas Valley Water
District and Clark County Water Reclamation District, pursuant to statutory and
regulatory standards and pricing.

                              Schedule "4" - Page 1

<Page>

                                  SCHEDULE "5"

                             PERMITTED ENCUMBRANCES

        1. Liens for Impositions which are not due and payable as of the Closing
Date or which are apportioned in accordance with Section 17.4.

        2. The state of facts shown on the survey to be delivered prior to
Closing Date described in Section 14.6 and any state of facts a physical
inspection of the Property would show (provided the same do not disclose any
matter materially adverse to the property which is not disclosed in the
Standards Document and which has not otherwise been disclosed in writing to Mall
II Buyer prior to the date hereof).

        3. Zoning, subdivision, environmental, building and all other Legal
Requirements presently existing, or enacted prior to the Closing Date,
applicable to the ownership, use or development of or the right to maintain or
operate the Phase II Mall or have space therein used and occupied by tenants.

        4. Leases reasonably satisfactory to Mall II Buyer reflecting the
expansions contemplated by Section 30.1 of each of the "Gondola Lease" and the
"VCR Showroom Lease" (as such terms are defined in the Mall I Agreement).

        5. The REA and, when executed, the Amended REA.

        6. Liens or Encumbrances arising as a result of the act or omission of
Mall II Buyer, its Consultants, agents, employees or Affiliates or acts of
Tenants and their contractors or subcontractors.

        7. Rights of Tenants, as tenants only, under the Leases.

        8. Sewer, water, electric, plumbing, heating, gas, telephone and other
utility easements and easements for ingress and egress for construction,
installation, operation and maintenance of municipal service facilities and
utilities, and all other covenants and other encumbrances of record that do not
interfere in any material respect with the use or operation of the Phase II
Mall.

        9. Promptly after the signing of this Agreement, Mall II Buyer and
Developer shall review the title report received in respect of the Mall Space
and shall reasonably agree upon additional items that should be added to this
Schedule "5" as Permitted Encumbrances.

                              Schedule "5" - Page 1
<Page>

                                  SCHEDULE "6"

       CONSENTS AND EXCEPTIONS (IF ANY) TO REPRESENTATIONS OF THE PARTIES

1.      Exceptions (If Any) to Developer's Representations: Developer advises
        that:

                           NONE

2.      Exceptions (If Any) to Mall II Buyer's Representations: Mall II Buyer
        advises Developer that:

                           NONE

                              Schedule "6" - Page 1
<Page>

                                  SCHEDULE "7"

                        MISCELLANEOUS CLOSING DELIVERIES

FROM DEVELOPER TO MALL II BUYER:

        1. Organizational Documentation of Developer:

        (a) certified copy of certificate of formation;

        (b) certificate(s) of good standing dated as of a date within 14 days of
the Closing Date, evidencing that Developer is in good standing in the State;

        (c) certificate of resolutions of the members of Developer authorizing
this Agreement and the transactions contemplated thereby on behalf of Developer
and Mall II LLC, if such is required; and

        (d) certificate of incumbency of Persons executing the Agreement on
behalf of Developer.

        2. Organizational Documentation of Mall II LLC:

        (a) certified copy of certificate of formation;

        (b) certificate(s) of good standing dated as of a date within 14 days of
the Closing Date, evidencing that Mall II LLC is in good standing in the State;
and

        (c) certified copy of Operating Agreement.

FROM MALL II BUYER TO DEVELOPER:

        3. Organization Documentation:

        (a) certified copy of certificate of limited partnership;

        (b) certificate of good standing dated as of a date within 14 days of
the Closing Date evidencing that Mall II Buyer is in good standing in the State;

        (c) certificate of resolutions of the partners of Mall II Buyer
authorizing this Agreement and the transactions contemplated thereby; and

        (d) certificate of incumbency of Persons executing the Agreement on
behalf of Mall II Buyer.

                              Schedule "7" - Page 1

<Page>

                                  SCHEDULE "8"

                  AUTHORIZED REPRESENTATIVES; NOTICE ADDRESSES

FOR DEVELOPER:

                  (a)      AUTHORIZED REPRESENTATIVES:
                           --------------------------

                  Sheldon G. Adelson, Chairman of the Board and Treasurer

                  William P. Weidner, President

                  Bradley H. Stone, Executive Vice President

                  Robert G. Goldstein, Senior Vice President

                  Harry D. Miltenberger, Secretary

                  (b)      NOTICE ADDRESS:
                           --------------

                           Lido Casino Resort, LLC
                           3355 Las Vegas Boulevard South
                           Room 1C
                           Las Vegas, NV  89109
                           Tel:  (702) 414-4409
                           Fax  (702) 414-4421
                           Attention:  Fred Kraus

                           with a copy to:

                           Paul, Weiss, Rifkind, Wharton & Garrison LLP
                           1285 Avenue of the Americas
                           New York, New York  10019
                           Tel.:  (212) 373-3000
                           Fax:  (212) 757-3990
                           Attention:  Harris B. Freidus, Esq.

FOR MALL II BUYER:

                              Schedule "8" - Page 1

<Page>

                  (a)      AUTHORIZED REPRESENTATIVES:
                           --------------------------

                  Joel Bayer

                  Tad Wefel

                  Tim Gardels

                  (b)      NOTICE ADDRESS:
                           --------------

                           GGP Limited Partnership
                           110 North Wacker Drive
                           Chicago, Illinois 60606
                           Tel.:  (312) 960-5015
                           Fax: (312) 960-5475
                           Attention:  Joel Bayer

                           with a copy to:

                           Neal, Gerber & Eisenberg, LLP
                           Two North LaSalle St., Suite 2100
                           Chicago, Illinois 60602
                           Tel.:  (312) 269-8000
                           Fax:  (312) 269-1747
                           Attention:  Marshall E. Eisenberg, Esq.

                              Schedule "8" - Page 1

<Page>

                                  SCHEDULE "9"

                       CONSTRUCTION SAFETY & HEALTH MANUAL

                              Schedule "9" - Page 1

<Page>

                                  SCHEDULE "10"

          ORGANIZATIONAL REPRESENTATIONS OF DEVELOPER AND MALL II BUYER

PART ONE - DEVELOPER:

        1. Developer is a limited liability company duly organized, validly
existing, and in good standing under the laws of the State and duly qualified to
transact business in the State.

        Developer has all necessary power and lawful authority to own and
operate its assets and properties and to carry on its business (including all
transactions contemplated under this Agreement and the Closing Instruments).

        Developer has delivered to Mall II Buyer a true, correct, and complete
copy of the certificate of formation by which Developer was formed, together
with all amendments thereof.

        The execution and delivery by Developer of this Agreement and the
Closing Instruments, and the consummation by Developer of the transactions
contemplated thereby, have been duly authorized by all necessary action of
Developer and duly approved by all members and managers of Developer whose
approval is required.

        The execution and delivery of this Agreement and the Closing Instruments
by Developer, and the consummation of the transactions contemplated hereby, will
not: (i) violate any provision of Developer's certificate of organization or the
limited liability operating agreement of Developer; or (ii) to the actual
knowledge of Developer and except for the failure to secure any consents
specified in SCHEDULE "6," result in the acceleration of any material
indebtedness of Developer.

PART TWO - MALL II BUYER:

        1. Mall II Buyer is a limited partnership duly organized and validly
existing under the laws of the State of Delaware.

        Mall II Buyer has all necessary power and lawful authority to own and
operate its assets and properties and to carry on its business (including all
transactions contemplated under this Agreement and the Closing Instruments).

        Mall II Buyer has delivered to Developer true and complete copies of the
certificate of limited partnership of Mall II Buyer by which Mall II Buyer was
formed, together with all amendments thereof.

        The execution and delivery of this Agreement and the Closing Instruments
by Mall II Buyer, and the consummation by Mall II Buyer of the transactions
contemplated thereby, have been duly authorized by all necessary action of Mall
II Buyer and duly approved by the directors of Mall II Buyer.

                             Schedule "10" - Page 1

<Page>

        The execution and delivery of this Agreement and the Closing Instruments
by Mall II Buyer, and the consummation of the transactions contemplated thereby,
will not: (a) violate any provision of Mall II Buyer's operating agreement; (b)
require the consent of any other Person except as set forth in SCHEDULE "6"; (c)
violate any judgment, order, injunction, award or decree of any Government
Authority against or binding upon Mall II Buyer or upon the property or business
of Mall II Buyer; (d) result in the acceleration of any material indebtedness of
Mall II Buyer.

        The officers and directors of Mall II Buyer are as follows:

        Mall II Buyer has no officers or directors.

        The following are all holders of direct and indirect ownership interests
in Mall II Buyer, other than those public shareholders of General Growth
Properties, Inc. or those limited partners of GGP Limited Partnership:

        SEE ATTACHED

        The following are all lenders or sources of financing to Mall II Buyer:

        None, other than institutional investors, as of execution of the
Agreement.

PART THREE - MALL II LLC:

        1. Mall II LLC is a limited liability company duly organized and validly
existing under the laws of a state as determined by Mall II Buyer and Developer.

        2. Mall II LLC has all necessary power and lawful authority to own and
operate its assets and properties and to carry on its business (including all
transactions contemplated under this Agreement and the Closing Instruments).

        3. Developer has delivered to Mall II Buyer a true, correct, and
complete copies of the certificate of formation of Mall II LLC and the Limited
Liability Company Agreement of Mall II LLC, together with all amendments
thereof.

        4. Prior to the Assignment, Mall II LLC was wholly owned by Developer.
Developer has consented to and approved consummation by Mall II LLC of the
transactions contemplated by this Agreement.

        5. The consummation by Mall II LLC of the transactions contemplated by
this Agreement will not: (a) violate any provision of Mall II LLC's Limited
Liability Company Agreement; (b) require the consent of any other Person except
as set forth in SCHEDULE "6," (c) violate any judgment, order, injunction, award
or decree of any Government Authority against or binding upon Mall II LLC or
upon the property or business of Mall II LLC; (d) result in the acceleration of
any material indebtedness of Mall II LLC.

                             Schedule "10" - Page 2

<Page>

                                  SCHEDULE "11"

           DEFINITIONS OF SUBSTANTIAL COMPLETION AND PUNCH LIST ITEMS

        1. "SUBSTANTIAL COMPLETION" means and shall be deemed to have occurred
when:

        (a) All Mall Improvement construction work is complete in accordance
with the Final Construction Drawings and Specs, as they may be revised pursuant
to Section 3.3 of the Agreement, and the requirements of Section 3.1 excepting
Punch List Items (defined below) and utilities except to the extent described
below;

        (b) All services bringing utilities to the Phase II Mall that are
required to be provided by Developer are installed to the point of connection
with the Tenant Space (in each case as specified in the Final Demising Wall
Plan) but not activated, tested or operating, and temporary electric service and
water sufficient for construction of the Build-Out is available to the Mall
Space but Developer shall not be obligated to bring the same to each Tenant
Space; and installations relating to telephone and telecommunications required
to be provided by Developer are installed;

        (c) Developer's Architect has certified that, in Developer's Architect's
opinion, all conditions to Substantial Completion have been met except for their
certifications and/or confirmations pursuant to this paragraph;

        (d) Mall II Buyer has received a copy of the certification (stating that
Mall II Buyer may rely thereupon) from Developer's Architect to Developer that,
to the Developer's Architects' professional knowledge, information and belief,
and to the level of observation provided in the Developer's Architects'
agreement with Developer, the Mall Improvement construction work exclusively
performed by Developer, but excluding any Tenant Spaces or other items relating
to the Build-Out, complies with all applicable building codes;

        (e) Developer has delivered to Mall II Buyer a record of all filings
with the buildings department of Clark County with respect to the Mall
Improvements through the date of Substantial Completion, including reports and
results of all controlled inspections for the Phase II Mall;

        (f) Developer has delivered to Mall II Buyer copies of the Required Mall
Improvement Permits;

        (g) All Demising Walls have been constructed as provided in the Final
Demising Wall Plan; and

        (h) Developer shall have delivered to Mall II Buyer a final certificate
of occupancy (or temporary certificate subject to the satisfaction of
non-material conditions, provided that full occupancy is permitted thereunder
and a permanent certificate of occupancy is obtained as promptly as possible
thereafter) for the

                             Schedule "11" - Page 1

<Page>

Mall Improvements exclusive of the Tenant Spaces. Mall II Buyer and Developer
acknowledge that the certificate of occupancy, permanent or temporary, covering
the Tenant Spaces shall be the responsibility of Mall II Buyer to obtain.

        For purposes of this Agreement, "PUNCH LIST ITEMS" means minor
touch-ups, corrections, and repairs, and completion of other minor work, none of
which is necessary for Mall II Buyer to operate the Phase II Mall.

                             Schedule "11" - Page 2

<Page>

                                  SCHEDULE "12"

                                       REA

                             Schedule "12" - Page 1
<Page>

                                  SCHEDULE "13"

                            MALL II BUYER LEGAL RATES

        Mall II Buyer will provide legal services to support joint leasing
efforts at an attorney rate of $325 per hour through 12/31/2005 and $350 per
hour thereafter. Paralegal time will be billed at a significantly lower rate.

                             Schedule "13" - Page 1
<Page>

                                  SCHEDULE "14"

                                 TENANT HANDBOOK

                             Schedule "14" - Page 1
<Page>

                                  SCHEDULE "15"

                            COST SHARING ALLOCATIONS

                             SECTION REFERENCES ON THIS SCHEDULE "15" ARE TO
                   THOSE CORRESPONDING SECTIONS OF THE REA, UNLESS OTHERWISE
                   SPECIFIED.

                   MALL I OWNER'S AND MALL II OWNER'S SHARE OF
                  HOTEL/CASINO/MALL/SECC COMMON AREA CHARGES*

<Table>
<Caption>

------------------------------ --------------------------------------- --------------------------------------
EXPENSE ITEM                   MALL I OWNER'S SHARE                    MALL II OWNER'S SHARE
------------------------------ --------------------------------------- --------------------------------------
------------------------------ --------------------------------------- --------------------------------------
<S>                             <C>                                     <C>

Maintenance of the Base        $185,000 per Accounting Period,**       Same as Mall I Owner's Share.
Building, Building Core and subject to CPI Adjustment.***
Shell, H/C-Mall Common Areas
and other common structures
and equipment)
------------------------------ --------------------------------------- --------------------------------------
------------------------------ --------------------------------------- --------------------------------------
Pest Control and Fire          The portion of all actual               Same as Mall I Owner's Share.
Extinguishers                  out-of-pocket costs related to pest
                               control and fire extinguisher service that is
                               related or allocable to the Phase I Mall, as
                               shown on bills received by the H/C I Owner from
                               the entities providing such pest control and fire
                               extinguisher services.
------------------------------ --------------------------------------- --------------------------------------
------------------------------ --------------------------------------- --------------------------------------
Parking Garage Cleaning        $30,000 per Accounting Period,          Same as Mall I Owner's Share.
                               subject to CPI Adjustment.
------------------------------ --------------------------------------- --------------------------------------
------------------------------ --------------------------------------- --------------------------------------
Parking Garage Security        $85,000 per Accounting Period,          Same as Mall I Owner's Share.
                               subject to CPI Adjustment.
------------------------------ --------------------------------------- --------------------------------------
------------------------------ --------------------------------------- --------------------------------------
Mall Valet Parking Charge      $125,000 per Accounting Period,         Same as Mall I Owner's Share.
                               subject to CPI Adjustment.
------------------------------ --------------------------------------- --------------------------------------
------------------------------ --------------------------------------- --------------------------------------

Off-Site Employee Parking      $760,000 per Accounting Period,         Same as Mall I Owner's Share.
                               subject to CPI Adjustment and further subject to
                               equitable adjustments (as determined by the
                               Independent Expert if Mall I Owner and H/C I
                               Owner cannot agree) if: (i) there are any rent
                               increases under the existing lease for the
                               off-site employee parking lot, (ii) the existing
                               lease for the off-site employee parking lot is
                               terminated and H/C I Owner enters into a new
                               lease for a new off-site employee parking lot,
                               and/or (iii) the existing lease for the off-site
                               employee parking lot is terminated and H/C I
                               Owner constructs a new off-site employee parking
                               facility on land it or an Affiliate or a
                               third-party owns. Any such equitable adjustment
                               pursuant to clause (iii) of the preceding
                               sentence shall be based on Mall I Owner's
                               equitable share, based on the respective off-site
                               employee parking needs of each Owner, of the fair
                               market rent for the applicable land (unless
                               leased from a third party and so already
                               addressed by clause (ii) of the preceding
                               sentence) and constructed facility.
------------------------------ --------------------------------------- --------------------------------------
------------------------------ --------------------------------------- --------------------------------------
Insurance Carried by H/C I     Mall I Owner's share of the             Same as Mall I Owner's Share.
Owner Pursuant to the          applicable insurance premiums shall
Provisions of Article X        be determined by the applicable
                               insurance carriers, pursuant to, and in
                               accordance with the procedures described in,
                               Section 1(c) of Article VI.
------------------------------ --------------------------------------- --------------------------------------
------------------------------ --------------------------------------- --------------------------------------
HVAC Plant and HVAC For each Accounting Period, the Same as Mall I Owner's
Share, Facilities --Operating Costs following annualized monthly charges subject
to adjustment by the ratio (other than the costs of itemized on the December 10,
2003 of (a) Gross Square Footage of the water, electricity and Sempra Energy
Solutions invoice Mall II Property (including master natural gas)**** addressed
to Grand Canal Shops Mall, leased casino level retail space and
                               LLC and attached hereto as Appendix I the
                               Walgreen's Air Rights Parcel) to this Schedule
                               II, subject to CPI (b) Gross Square Footage of
                               the Mall Adjustment: Procurement Charge; I
                               Property.
                               Central Plant; Other Facilities; Central Plant
                               Real Estate Taxes; and Other Facilities Real
                               Estate Taxes.
------------------------------ --------------------------------------- --------------------------------------
------------------------------ --------------------------------------- --------------------------------------
HVAC Plant - Water, $1,500,000 for 2004, adjusted Same as Mall I Owner's Share,
Electricity and Natural Gas annually thereafter as follows: For subject to
adjustment by the ratio Costs**** every one percent (1%) increase in of (a)
Gross Square Footage of the
                               the amounts charged by the applicable   Mall II Property (including master
                               electricity providers and               leased casino level retail space and
                               transporters from the first day of      the Walgreen's Air Rights Parcel)
                               the prior Accounting Period to the      (b) Gross Square Footage of the Mall
                               first day of the applicable             I Property.
                               Accounting Period (assuming no change
                               in the amount of electricity provided
                               and transported), there shall be an
                               eight-tenths of one percent (.8%)
                               increase in the amount owed by Mall I
                               Owner.  For every one percent (1%)
                               increase in the amounts charged by
                               the applicable natural gas providers
                               and transporters from the first day
                               of the prior Accounting Period to the
                               first day of the applicable
                               Accounting Period (assuming no change
                               in the amount of natural gas provided
                               and transported), there shall be an
                               eighteen one-hundredths of one
                               percent (.18%) increase in the amount
                               owed by Mall I Owner.  For every one
                               percent (1%) increase in the amounts
                               charged by the applicable water
                               providers and transporters from the
                               first day of the prior Accounting
                               Period to the first day of the
                               applicable Accounting Period
                               (assuming no change in the amount of
                               water provided and transported),
                               there shall be a two one-hundredths
                               of one percent (.02%) increase in the
                               amount owed by Mall I Owner.
------------------------------ --------------------------------------- --------------------------------------
------------------------------ --------------------------------------- --------------------------------------
HVAC Plant and HVAC For each Accounting Period, the sum Same as Mall I Owner's
Share, Facilities --Amortization of of (x) $1,645,000 PLUS (y) the amount
subject to adjustment by the ratio Initial HVAC Plant and HVAC of payments to be
made by Mall I of (a) Gross Square Footage of the Facilities Construction Owner
pursuant to paragraph 1(g) of Mall II Property (including master Costs and Other
Capital Schedule 4.2 of its ESA (without leased casino level retail space and
Expenditures**** giving effect to this Schedule II or the Walgreen's Air Rights
Parcel)
                               the Agreement); provided, however,      (b) Gross Square Footage of the Mall
                               that if, in any Accounting Period,      I Property.
                               the applicable major repairs,
                               replacements and capital investments
                               (excluding those relating to the
                               Other Facilities (as defined in
                               Mall I Owner's ESA)) exceed
                               $5 million, and either Mall I Owner
                               or H/C I Owner believes that Mall I
                               Owner's "Proportionate Share" (as
                               defined in Mall I Owner's ESA) is
                               not, taking into account all relevant
                               factors, Mall I Owner's equitable
                               share of such repairs, replacements
                               and investments, then the actual
                               equitable share, as agreed to by
                               Mall I Owner and H/C I Owner (or, if
                               such parties cannot agree, as
                               determined by the Independent Expert)
                               shall be deemed to be Mall I Owner's
                               "Proportionate Share" for purposes of
                               calculating the amount described in
                               the foregoing clause (y).
------------------------------ --------------------------------------- --------------------------------------
------------------------------ --------------------------------------- --------------------------------------
Water                          $120,000 for 2004, adjusted annually    Same as Mall I Owner's Share,
                               thereafter based on the percentage      subject to adjustment by the ratio
                               increase, if any, in amounts charged    of (a) Gross Leasable Square Footage
                               by the applicable water providers and   of the Mall II Property (including
                               transporters from the first day of      Level 92' Retail Space and the
                               the prior Accounting Period to the      Walgreen's Air Rights Parcel) (b)
                               first day of the applicable             Gross Leasable Square Footage of the
                               Accounting Period (assuming no change   Mall I Property.
                               in the amount of water provided).
------------------------------ --------------------------------------- --------------------------------------
------------------------------ --------------------------------------- --------------------------------------
Sewer                          $96,000 for 2004, adjusted annually     Same as Mall I Owner's Share,
                               thereafter based on the percentage      subject to adjustment by the ratio
                               increase, if any, in the amounts        of (a) Gross Square Footage of the
                               charged by the applicable utility       Mall II Property (including Level
                               companies from the first day of the     92' Retail Space and the Walgreen's
                               prior Accounting Period to the last     Air Rights Parcel) (b) Gross Square
                               day of the applicable Accounting        Footage of the Mall I Property.
                               Period.
------------------------------ --------------------------------------- --------------------------------------
------------------------------ --------------------------------------- --------------------------------------
CAM Electric                   $240,000 for 2004, adjusted annually    Same as Mall I Owner's Share,
                               thereafter based on the percentage      subject to adjustment by the ratio
                               increase, if any, in the amounts        of (a) Gross Common Area Square
                               charged by the applicable electricity   Footage of the Mall II Property
                               providers and transporters from the     (including Level 92' Retail Space
                               first day of the prior Accounting       and the Walgreen's Air Rights
                               Period to the first day of the          Parcel) (b) Gross Common Area Square
                               applicable Accounting Period            Footage of the Mall I Property.
                               (assuming no change in the amount of
                               electricity provided).
------------------------------ --------------------------------------- --------------------------------------
------------------------------ --------------------------------------- --------------------------------------
Legal/Accounting               If it is reasonably necessary for, or   Same as Mall I Owner's Share.
                               if Mall I Owner requests, H/C I Owner
                               to perform, or engage third parties
                               to perform, legal or accounting
                               services on behalf of Mall I Owner,
                               such charges shall be paid for by Mall I Owner in
                               an amount equal to the actual out-of-pocket costs
                               incurred by H/C I Owner on account of such
                               services. If the legal or accounting services
                               benefit more than one Owner, the costs shall be
                               divided equally among the Owners.
------------------------------ --------------------------------------- --------------------------------------
------------------------------ --------------------------------------- --------------------------------------
Electric Substation capital    15% of all such expenditures.           15% of all capital expenditures
expenditures (I.E.,                                                    related to the Phase II Electrical
              ----
expenditures that, under                                               Substation, excluding the initial
generally accepted                                                     cost of construction, if any.
accounting principles
consistently applied, cannot
be expensed in the year in
which they are incurred)
------------------------------ --------------------------------------- --------------------------------------
------------------------------ --------------------------------------- --------------------------------------
Fire Suppression/Sprinkler     100% of all costs incurred by H/C I     Same as Mall I Owner's Share.
Systems                        Owner in connection with its
                               obligations under Section 1(b) of Article V, to
                               the extent such obligations relate to those
                               portions of all fire suppression systems
                               (including sprinklers) located within the Mall I
                               Space.
------------------------------ --------------------------------------- --------------------------------------
------------------------------ --------------------------------------- --------------------------------------
All costs and expenses         100% of such costs.                     Same as Mall I Owner's Share.
caused by, attributable to
or necessitated by (i) Mall
I Owner's or any Mall I Occupant's moving property in or out of the Mall I Space
or installation or removal of furniture, fixtures or other property, (ii) the
performance by Mall I Owner or any Mall I Occupant of any Alterations, (iii) the
negligence or willful misconduct of Mall I Owner or any Mall I Occupant or the
agents, employees, contractors, invitees and other Permittees of either of them,
(iv) any breach by Mall I Owner of the Agreement, or (v) any breach by any Phase
I Mall Tenant of its Lease.
------------------------------ --------------------------------------- --------------------------------------

</Table>

NOTES:

*Whenever any definite amount (subject to CPI Adjustment or any other
adjustment) is set forth on this chart as a payment for a certain category of
expenses, such amount (adjusted for CPI or as otherwise adjusted) shall be due
and payable by Mall I Owner to H/C I Owner without regard to the amount actually
incurred by H/C I Owner in respect of that category of expenses (and thus, no
Supporting Documentation pursuant to Section 3(e) of Article V shall be required
to be provided in connection therewith).

**All specified amounts in Schedule II shall be appropriately pro-rated for 2004
(except for purposes of calculating future CPI Adjustments).

<Page>

                  ***"CPI ADJUSTMENT," as used on this Schedule II, shall be
calculated as follows: Each specified dollar amount that is subject to CPI
Adjustment shall be adjusted as of the first day of each Accounting Period,
beginning with the 2005 Accounting Period, by multiplying such dollar amount (as
it may have previously been adjusted pursuant to this sentence) by the
percentage that is the sum of (x) one hundred percent (100%), plus (y) one
hundred percent (100%) of the CPI Increase (as defined in the following
sentence). "CPI INCREASE" shall mean the percentage increase or decrease, if
any, that has occurred in the CPI from the calendar month which is sixteen
months prior to the calendar month in which the applicable Accounting Period
begins to the calendar month which is four months prior to the calendar month in
which the applicable Accounting Period begins. (For example, if a CPI Adjustment
is being calculated for the Accounting Period that begins January 1, 2007, the
CPI Increase would be the percentage increase that has occurred in the CPI from
September, 2005 to September, 2006). As so adjusted, such amount will be
utilized until the next CPI Adjustment is calculated as of the first day of the
next Accounting Period. "CPI" means the Consumer Price Index for All Urban
Consumers published by the Bureau of Labor Statistics of the United States
Department of Labor, U.S. City Average, All Items 1982-1984=100, or any
successor thereto appropriately adjusted. If the Consumer Price Index ceases to
be published, and there is no successor thereto, such other index as the parties
hereto reasonably agree upon (or, if they cannot so agree, such other index as
the Independent Expert shall determine in accordance with Article 9), as
appropriately adjusted, shall be substituted for the Consumer Price Index.

****Only applicable during the Sempra Term.

<Page>

                                  SCHEDULE "16"

                             MASTER LEASE AGREEMENT

                             Schedule "16" - Page 1

<Page>

                                  SCHEDULE "17"

                              INTENTIONALLY OMITTED

                             Schedule "17" - Page 1

<Page>

                                  SCHEDULE "18"

                                     LEASES

No third party has a right, option or election to lease space in the Phase II
Mall other than those rights, options or elections contained in "Leases" (as
defined in the Phase I Mall Sale Agreement).

                             Schedule "18" - Page 1
<Page>

                                  SCHEDULE "19"

                           GAMING PROVISION FOR LEASES

                  "Tenant acknowledges that Landlord and the Lido Casino Resort,
LLC and their affiliates are businesses that are or may be subject to privileged
licenses issued by governmental authorities relating to casino gaming ("GAMING
AUTHORITIES"). If a corporation, Tenant shall disclose the names of all officers
and directors of Tenant, and unless a publicly traded corporation on a national
stock exchange, Tenant shall disclose to Landlord all ownership interests in
Tenant and all lenders or sources of financing. If requested to do so by
Landlord, Tenant shall obtain any license, qualification, clearance or the like
which shall be requested or required of Tenant by any Gaming Authority or any
regulatory authority having jurisdiction over Landlord or any affiliate of
Landlord. If Tenant fails to satisfy such requirement or if Landlord or any
affiliate of Landlord is directed to cease business with Tenant by any such
authority, or if Landlord shall in good faith determine, in Landlord's
reasonable judgment, that Tenant, or any of its officers, directors, employees,
agents, designees or representatives, or partner, owner, member, or shareholder,
or any lender or financial participant (a) is or might be engaged in, or is
about to be engaged in, any activity or activities, or (b) was or is involved in
any relationship, either of which could or does jeopardize Landlord's business,
reputation or such licenses, or those of its affiliates, or if any such license
is threatened to be, or is, denied, curtailed, suspended or revoked, then Tenant
shall immediately (i) terminate any relationship with the individual or entity
which is the source of the problem, or (ii) cease the activity creating the
problem. If Tenant does not comply with item (i) or (ii) above, then Landlord
(x) may require Tenant to specifically perform such obligation (the parties
recognizing that damages or other remedies would be inadequate under the
circumstances) or (y) may terminate this Lease without liability to either
party; provided, however, if any matter described herein is reasonably
susceptible to cure, Tenant shall have a reasonable time within which to effect
such cure (but in no event longer than the time available to fully comply with
any requirement imposed by any Gaming Authority or any other Requirement) and
Landlord shall not have the right to terminate this Lease during such cure
period."

                             Schedule "19" - Page 1

<Page>

                                  SCHEDULE "20"

                           WORK CONTINUATION AGREEMENT

                             Schedule "20" - Page 1
<Page>

                                    EXHIBIT A

                               STANDARDS DOCUMENT

                               Exhibit A - Page 2
<Page>

                                    EXHIBIT B

                     DEVELOPER'S REPRESENTATION CERTIFICATE

                  LIDO CASINO RESORT, LLC, a Nevada limited liability company
with an office at 3355 Las Vegas Boulevard South, Room 1C, Las Vegas, NV 89109
("DEVELOPER"), hereby certifies that the representations and warranties of the
undersigned set forth in Section 15.1 of the Agreement by and between Developer,
as Developer, and GGP LIMITED PARTNERSHIP, as Mall II Buyer, dated as
___________, 2004 (the "Agreement") are true and correct in all material
respects as of the date hereof [, except that ]. This certificate is made
subject to the limitations on scope, liability and survival, limitations on
Developer's knowledge and other matters regarding Developer's representations
and warranties set forth in the Agreement (including, without limitation, in
Sections 15.10 and 15.12 and the definition of "knowledge" or "notice").
                  Executed as of this         day of _________, 2004.
                                      -------

             LIDO CASINO RESORT, LLC

             By:  Lido Casino Resort Holding Company, LLC

                  By:  Lido Intermediate Holding Company, LLC

                       By:  Venetian Casino Resort, LLC

                            By:   Las Vegas Sands, Inc.

                                  By:
                                       --------------------------------------
                                       Name:
                                       Title:

                               Exhibit B - Page 1EX-10.2                         AGREEMENT OF PURCHASE AND SALE

                       AGREEMENT OF PURCHASE AND SALE

     This Agreement of Purchase and Sale (this "Agreement") is
entered into as of December 19, 2003, by and between Avery Sports
Turf, Inc., a Delaware Corporation ("Buyer"); Jural E. Avery ("Mrs.
Avery"), an individual residing in Floyd County, Georgia; George Avery
("Mr. Avery"), an individual residing in Floyd County, Georgia; and
Avery Sports Turf, Inc., a Georgia Corporation ("Avery Georgia").  At
times herein, Mrs. Avery, Mr. Avery and Avery Georgia are referred to
collectively as "Sellers." This Agreement constitutes (i) a contract
of purchase and sale among the parties and (ii) escrow instructions to
Escrow Agent (as hereinafter defined).

     THE PARTIES ENTER INTO THIS AGREEMENT on the basis of the
following facts, understandings and intentions:

     A. As more particularly described in the next succeeding
recitals of this Agreement, Sellers together own all of the assets of
"Avery Sports Turf" (the "Business"), an enterprise located in Rome,
Georgia, engaged in the business of manufacturing artificial sports
turf and related play surfacing materials (the "Products").

     B. Mrs. Avery owns the real property comprised of approximately
3.55 acres, located at 9 Riverside Industrial Park, in the City of
Rome, County of Floyd, State of Georgia, as more particularly
described on the attached Exhibit 1 (herein the "Land") and the
Improvements (defined below) located upon the Land, together with Mrs.
Avery's interest in (i) all rights, privileges, easements and right-
of-ways appurtenant thereto, (ii) all warranties in connection with
the Improvements, (iii) to the extent assignable, all entitlements,
permits and other intangible property used in connection therewith,
and (iv) to the extent assignable, all contract rights related to the
ownership, use and operation thereof (collectively, including such
Land and Improvements, the "Property");

     C. Mr. Avery and/or Avery Georgia own certain industrial
machinery located and installed at the Property, as more particularly
described on the attached Exhibit 2, together with (i) Mr. Avery's and
Avery Georgia's interests in (i) all warranties in connection with the
Equipment, (ii) to the extent assignable, all entitlements, permits
and other intangible property used in connection therewith, and (iii)
to the extent assignable, all contract rights related to the
ownership, use and operation thereof (collectively, the "Equipment");

     D. Mr. Avery and/or Avery Georgia own certain letters patent
and patents, provisional patent applications, patent applications,
patent licenses, know-how, trade names, brand names, trademarks,
inventions, technology, trade secrets, customer lists, inventory,
ideas, processes, documentation, design documentation and
specifications, and tangible or intangible proprietary information or
material (herein the "Intellectual Property", more particularly
described in the attached Exhibit 3);

     E. Mr. Avery and/or Avery Georgia own certain other assets
related to or associated with the Business (excluding the Excluded
Assets), including Customer (defined hereinbelow) lists, Accounts
Receivable (as defined hereinbelow), prepaid expenses, Inventories
(defined hereinbelow), work in progress under Assumed Customer
Contracts (defined hereinbelow), books of account, customer lists,
price lists, correspondence, data, sales literature, sales data,
accounting information relating to the Business, client files (for
active and inactive matters), books and records, files, personnel
files of employees of the Business who are employed by Buyer from and
after the Closing, data bases, manuals, e-mails, ledgers, papers and
records and tax returns, in whatever form or medium related to the
Business, all goodwill related to the Business, all telephone numbers,
e-mail addresses, websites, and domain names related to the Business,
all causes of action, judgments and claims or demands against others
of whatever kind or description related to the Business, and all other
property owned or used by said Sellers, whether tangible or
intangible, used by or in the Business and located at the Property,
whether or not expressly referred to herein (all of the foregoing
being at times referred to herein as the "Other Business Assets"). In
addition, Mr. Avery and/or Avery Georgia have indebtedness and/or
liabilities related to or associated with the Business (the "Assumed
Liabilities"), more particularly described in the attached Exhibit 4),
which are to be assumed by Buyer hereunder;

     F. The parties desire to effect a business combination whereby
(1) the Sellers will sell, and Buyer will purchase, substantially all
of the assets of the Business; viz: the Property, the Equipment, the
Intellectual Property, and the Other Business Assets (collectively
herein the "Acquired Assets"), and (2) Buyer will assume certain
indebtedness of Sellers, more particularly described hereinbelow, on
the terms, covenants and conditions provided herein; and

     G. For purposes of this Agreement, the following terms shall
have the meanings given below:

     G.1. "Accounts Receivable" means all rights to payment for
goods sold, licensed or leased or for services rendered to Customers
in connection with the Business, all sums of money or other proceeds due or
becoming due thereon and all instruments pertaining thereto;

     G.2. "Acquired Assets" has the meaning set forth in recital "F"
above;

     G.3. "Assumed Liabilities" has the meaning set forth in recital
"E" above and more particularly described in the attached Exhibit 4;

     G.4. "Assumed Customer Contracts" means the Customer Contracts
assumed by Buyer hereunder and listed as such on the attached Exhibit 5;

     G.5. "Bank Debt" has the meaning set forth in Exhibit 4;

     G.6. "Business" has the meaning set forth in recital "A" above;

     G.7. "Business Day" shall mean any day other than a Saturday,
Sunday or day on which banks in the state of Georgia are authorized to
be closed for business;

     G.8. "Claim"  means (i) a right to payment, whether or not such
right is reduced to judgment, liquidated, unliquidated, fixed,
contingent, matured, unmatured, disputed, undisputed, legal,
equitable, secured or unsecured or (ii) a right to an equitable remedy
for breach of performance if such breach gives rise to a right to
payment, whether or not such right to an equitable remedy is reduced
to judgment, fixed, contingent, matured, unmatured, disputed,
undisputed, secured or unsecured;

     G.9. "Closing" means the consummation of the transactions
contemplated hereby, and the recordation of the instruments necessary
to vest good title to the Property and the Equipment in Buyer in
accordance with the terms and provisions of this Agreement;

     G.10. "Closing Date" means a date when the Close of
Escrow has occurred;

     G.11. "Code" means the Internal Revenue Code of 1986, any
amendments thereto, any successor statutes and any regulations
promulgated thereunder;

     G.12. "Customers" means Mr. Avery's and Avery Georgia's entire
end user customer base with regard to the Business;

     G.13. "Customer Contracts" means any and all contracts and
agreements related to the Customers listed on Exhibit 5 of this
Agreement;

     G.14. "Employees" means all employees of Mr. Avery and Avery
Georgia engaged primarily in the Business;

     G.15. "Escrow Agent" means William M. Phillips, 7480
Nashville Street, Ringgold, Georgia 30736;

     G.16. "Execution Date" shall mean the date set forth at the
beginning hereof.

     G.17. "Excluded Assets" has the meaning set forth in Section 5;

     G.18. "Excluded Liabilities" has the meaning set forth in Section 5;

     G.19. "Governmental Authority" means any agency, board, bureau,
executive, court, commission, department, legislature, tribunal,
instrumentality or administration of the United States, or any state,
provincial, territorial, municipal, county, local or other
governmental entity in the United States;

     G.20. "Governmental Permits" means all licenses, permits,
approvals, consents, certificates, waivers, exemptions, orders,
registrations, variances and other authorizations from any and all
Governmental Authorities, including any state sales tax numbers, used
or held for use in connection with the conduct of the Business;

     G.21. "Improvements" shall mean a four story industrial
building consisting of approximately One Hundred Seven Thousand Eight
Hundred Eighty-four (107,884) square feet;

     G.22. "Intellectual Property" has the meaning set forth in
recital "D" above;

     G.23. "Inventories" means all inventories of raw materials,
works in process, finished products, goods, spare parts, replacement
and component parts, and office and other supplies;

     G.24. "Knowledge of Sellers" means the actual knowledge, after
due inquiry, of Mr. Avery, Mrs. Avery and Mr. Avery as President and
Chief Executive Officer of Avery Georgia;

     G.25. "Law" means any law, statute, regulation, rule, code,
ordinance or court order enacted, adopted, issued or promulgated by
any Governmental Authority;

     G.26. "Liability" or "Liabilities" means any and all material
liabilities, obligations, judgments, damages, charges, costs, debts
and indebtedness of any and every kind and nature whatsoever, absolute
or contingent, liquidated or unliquidated, in Law, equity or
otherwise;

     G.27. "Lien" means, with respect to any asset or property of
any character, any mortgage, pledge, security interest, lien
(including any mechanic's or materialman's lien, tax lien, shipper or
warehousemen lien or customs lien), right of first refusal, option or
other right to acquire, transfer for security, charge, Claim,
easement, conditional sale agreement, title retention agreement,
defect in title, or other encumbrance or adverse Claim of any nature
pertaining to or affecting such asset or property, whether voluntary
or involuntary and whether arising by Law, contract or otherwise,
including without limitation, in the case of any Accounts Receivable,
any right or claim of any person other than Sellers upon or with
respect to the proceeds thereof;

     G.28. "Material Adverse Change" means any change or changes in,
or effect on, the Business or the Acquired Assets that is
individually, or are in the aggregate, reasonably likely to be
materially adverse to the financial condition of the Business or the
Acquired Assets, each taken as a whole, other than (i) any change or
effect in any way resulting from or arising in connection with this
Agreement or any of the transactions contemplated hereby (including
any announcement with respect to this Agreement or any of the
transactions contemplated hereby); (ii) changes in (A) economic,
regulatory or political conditions generally or (B) general business
or economic conditions relating to any industries in which any of
Sellers participates, that is not specific to such Seller; (iii) any
change in or effect on the Acquired Assets or the Business that is
cured (including by the payment of money) by the applicable Seller,
(iv) any change in or effect on the Acquired Assets or the Business
resulting from any loss of Customers (including any reduction in
revenue therefrom), and (v) any change in or effect on the Acquired
Assets or the Business resulting from the resignations of any Employees;

     G.29. "Ordinary Course of Business" means the ordinary course
of business of Sellers and consistent with Sellers' past custom and
practice;

     G.30. "Other Business Assets" has the meaning set forth in
recital "E" above;

     G.31. "Permitted Encumbrances" means (i) statutory liens for
current Taxes or assessments not yet due or delinquent, (ii)
mechanics', carriers', workers', repairers' and other similar liens
arising or incurred in the Ordinary Course of Business relating to
obligations as to which there is no default on the part of any of
Sellers or the validity or amount of which is being contested in good
faith by appropriate proceedings, or pledges, deposits or other liens
securing the performance of bids, trade contracts, leases or statutory
obligations (including workers' compensation, unemployment insurance
or other social security legislation), (iii) zoning, entitlement,
conservation restriction and other land use and environmental
regulations by Governmental Authorities which do not materially
interfere with the present use of the Acquired Assets, and (v) such
other liens, imperfections in or failure of title, charges, easements,
rights-of-way, encroachments, exceptions, restrictions and
encumbrances which do not materially interfere with the present use of
the Acquired Assets;

     G.32. "Person" means any individual, corporation, partnership,
proprietorship, joint venture, limited liability company, association,
joint-stock company, trust, unincorporated organization, Governmental
Authority, or other entity, organization or institution of any type
whatsoever;

     G.33. "Sellers" has the meaning set forth in the preamble;

     G.34. "Tax" means any federal, state, local, or other income,
alternative, minimum, inheritance, accumulated earnings, personal
holding company, corporation, franchise, capital stock, net worth,
capital, profits, windfall profits, capital gain, gross receipts,
value added, sales, use, goods and services, excise, customs duties,
transfer, conveyance, mortgage, registration, stamp, documentary,
recording, premium, environmental, real property, personal property,
ad valorem, intangibles, rent, occupancy, license, occupational,
employment, unemployment insurance, social security, disability,
workers' compensation, payroll, health care, withholding, estimated or
other similar tax, duty or other governmental charge or assessment or
deficiencies thereof (including all interest and penalties thereon and
additions thereto whether disputed or not);

     G.35. "Tax Return" means any return, report, declaration, form,
Claim for refund or information return or statement relating to Taxes,
including any schedule or attachment thereto, and including any
amendment thereof;

     G.36. "Title Company" shall mean AAA Land and Title Agency,
7480 Nashville Street, Ringgold, Georgia 30736;

     NOW, THEREFORE, IN CONSIDERATION of the mutual covenants and
agreements of the parties as herein set forth, the parties hereto
agree as follows:

     1. Real Estate Purchase. Mrs. Avery agrees to sell the
Property to Buyer, and Buyer agrees to purchase the Property from Mrs.
Avery, on all of the terms, covenants and conditions provided herein.

     2. Equipment Purchase. Mr. Avery and Avery Georgia agree to
sell the Equipment to Buyer, and Buyer agrees to purchase the
Equipment from Mr. Avery and Avery Georgia, on all of the terms,
covenants and conditions provided herein.

     3. Intellectual Property Purchase.  Mr. Avery and Avery Georgia
agree to sell the Intellectual Property to Buyer, and Buyer agrees to
purchase the Intellectual Property from Mr. Avery and Avery Georgia,
on all of the terms, covenants and conditions provided herein. At the
Closing, Mr. Avery and Avery Georgia shall execute the form of
Assignment attached as Exhibit 6. Other than the rights expressly set
forth herein, Mr. Avery and Avery Georgia shall, after the Closing,
have no further or continuing interest in the Intellectual Property,
nor any other patent or technology related to the Patents. At the
Closing, Mr. Avery and Avery Georgia shall provide to Buyer the
original certificates reflecting the registrations of the Intellectual
Property, as well as all files in their possession regarding the
technology embodied in the Intellectual Property. Mr. Avery and Avery
Georgia further agree at any time after the Closing to execute and to
deliver upon request of the Buyer, at Buyer's expense, such additional
documents, if any, as may be necessary or desirable to protect the
Intellectual Property or to give full effect to this Agreement.

     4. Other Business Assets Purchase.  Mr. Avery and Avery Georgia
agree to sell the Other Business Assets to Buyer, and Buyer agrees to
purchase the Other Business Assets from Mr. Avery and Avery Georgia,
on all of the terms, covenants and conditions provided herein.

     5. Excluded Assets and Liabilities. The transactions
contemplated herein shall not include the purchase and sale of the
assets more particularly described in the attached Exhibit 7 (the
"Excluded Assets") or the assumption by Buyer of the liabilities more
particularly described in the attached Exhibit 8 (the "Excluded
Liabilities").

     6. Deposit. Buyer has paid to Mrs. Avery and Mr. Avery the sum
of Thirty Thousand Dollars ($30,000.00) in cash ("Deposit") as a
deposit on account of the Purchase Price (as defined in Section 4).
The Deposit shall be nonrefundable, except as provided in Section 3(b)
below.  Mrs. Avery and Mr. Avery acknowledge receipt of the Deposit by
their execution of this Agreement. Payments made to Greater Rome Bank
and Insurance to bind coverage are considered part of the $30,000.

     7. Liquidated Damages/Default.

     a. Buyer's Default. IN THE EVENT THAT THE SALE OF THE
PROPERTY AND THE EQUIPMENT DOES NOT CLOSE AS A CONSEQUENCE OF A
DEFAULT BY BUYER, AND IF NEITHER MRS. AVERY NOR MR. AVERY IS IN
DEFAULT OF ANY OF THEIR OBLIGATIONS UNDER THIS AGREEMENT AND HAVE
PERFORMED ALL OBLIGATIONS TO BE PERFORMED HEREUNDER AS OF THE TIME OF
BUYER'S DEFAULT, SELLERS SHALL BE ENTITLED EITHER TO (i) RETAIN THE
AMOUNT OF THE DEPOSIT AS LIQUIDATED DAMAGES, OR (ii) SPECIFIC
PERFORMANCE OF BUYER'S OBLIGATION TO PURCHASE THE PROPERTY AND THE
EQUIPMENT; PROVIDED, HOWEVER, IN THE EVENT SELLERS ELECT TO SEEK
SPECIFIC PERFORMANCE AND ARE UNSUCCESSFUL IN OBTAINING SPECIFIC
PERFORMANCE, SELLERS SHALL BE ENTITLED TO RETAIN THE AMOUNT OF THE
DEPOSIT AS LIQUIDATED DAMAGES. THE PARTIES AGREE THAT SELLERS' ACTUAL
DAMAGES WOULD BE DIFFICULT OR IMPOSSIBLE TO DETERMINE IF BUYER
DEFAULTS, AND THE AMOUNT OF THE DEPOSIT IS THE BEST ESTIMATE OF THE
AMOUNT OF DAMAGES SELLERS WOULD SUFFER. THE PARTIES ACKNOWLEDGE THAT
THE SUM REPRESENTED BY BUYER'S DEPOSIT CONSTITUTES A REASONABLE
ESTIMATE OF SELLERS' DAMAGES. SELLERS AGREE THAT THEY WILL ACT
TOGETHER IN ACCORDANCE WITH THIS SECTION 4(a) AND WILL NOT SEEK
SEPARATE OR CONFLICTING REMEDIES.

     b. Sellers' Default. IF EITHER OF THE SELLERS REFUSES OR
FAILS TO CONVEY THE PROPERTY OR THE EQUIPMENT PURSUANT TO THIS
AGREEMENT FOR ANY REASON EXCEPT A DEFAULT BY BUYER HEREUNDER, BUYER,
AS ITS SOLE AND EXCLUSIVE REMEDY (EXCEPT AS PROVIDED IN SECTION 7(f)
BELOW), SHALL BE ENTITLED EITHER TO (i) TERMINATE THIS AGREEMENT AND
RECOVER THE DEPOSIT AND, IF APPLICABLE THE LIQUIDATED DAMAGES COMPUTED
PURSUANT TO SECTION 7(e) BELOW, OR (ii) SPECIFIC PERFORMANCE OF
SELLERS' OBLIGATIONS TO CONVEY THE PROPERTY AND THE EQUIPMENT,
PROVIDED THAT NO SUCH ACTION FOR SPECIFIC PERFORMANCE SHALL SEEK TO
REQUIRE EITHER OF THE SELLERS TO DO ANY OF THE FOLLOWING: (A) CHANGE
THE CONDITION OF THE PROPERTY OR THE EQUIPMENT, OR RESTORE THE SAME
AFTER ANY CASUALTY (EXCEPT AS EXPRESSLY PROVIDED IN SECTION 13), OR
(B) EXPEND MONEY OR POST A BOND TO REMOVE A TITLE ENCUMBRANCE OR
DEFECT (EXCEPT LIENS OR ENCUMBRANCES CREATED BY SUCH SELLER. IN THE
EVENT BUYER SEEKS SPECIFIC PERFORMANCE AND IS UNSUCCESSFUL IN
OBTAINING SPECIFIC PERFORMANCE, BUYER SHALL BE ENTITLED TO TERMINATE
THIS AGREEMENT AND RECOVER THE DEPOSIT. BUYER SHALL BE DEEMED TO HAVE
ELECTED TO TERMINATE THIS AGREEMENT IF BUYER FAILS TO DELIVER TO
SELLERS WRITTEN NOTICE OF ITS INTENT TO ASSERT A CAUSE OF ACTION FOR
SPECIFIC PERFORMANCE WITHIN THIRTY (30) DAYS FOLLOWING THE SCHEDULED
CLOSING DATE OR, HAVING GIVEN SUCH NOTICE, FAILS TO FILE A LAWSUIT
ASSERTING SUCH CAUSE OF ACTION IN THE PROPER COURT WITHIN SIXTY (60)
DAYS FOLLOWING THE SCHEDULED CLOSING DATE.

     c. Cure Period for Default. Prior to termination of this
Agreement by either party for default, the party alleging default
shall give the defaulting party or parties written notice thereof, and
the defaulting party or parties shall have ten (10) days from receipt
of such notice to cure such default.

     8. Consideration and Purchase Price. In consideration for the
Acquired Assets and in full payment therefore, Buyer shall assume the
Assumed Liabilities as provided herein and shall deliver to Sellers at
Closing the following consideration (with the items referred to in
clauses (a), (b) and (c) being referred to collectively as the
"Purchase Price"):

     a. Application of the Deposit; and

     b. a Promissory Note, in the amount of Two Hundred
Thousand Dollars ($200,000) substantially in the form of the attached
Exhibit 9 (the "Note"), to be secured at Closing by a second mortgage
on the Property; and

     c. The assumption of the Assumed Liabilities.

     9. Conditions Precedent. At or before Close of Escrow the
following conditions precedent ("Conditions Precedent") shall be
either satisfied or waived by Buyer as a condition to Buyer's
obligation to proceed with the purchase of the Property and the
Equipment:

     a. Title. The term "Conditions of Title" shall refer to
those exceptions to title (including, without limitation, Title
Company's standard printed exceptions to title with respect to an ALTA
Owner's Extended Form policy of title insurance (an "ALTA Policy"),
the lien for real property taxes not delinquent, any current
assessments (subject to Mrs. Avery's obligation to pay delinquent
assessments or credit same to the Purchase Price at closing), and the
effect of any other encumbrances or matters of title caused or
approved in writing by Buyer. On the Closing Date, Title Company shall
be unconditionally committed to issue an American Land Title
Association ("ALTA") Extended Title Policy Form B (1970) for the
Property ("ALTA Title Policy"), with a liability limit in the amount
of the combined total of the Note and the Bank Debt and insuring fee
title vested in Buyer (in addition, the Equipment shall not be subject
to any liens or encumbrances of record);

     b. Property Documents. Buyer has reviewed and approved
all title reports and other documents and reports pertinent to the
Property and the Equipment (the "Property Documents"). As of the Close
of Escrow there shall have been no material adverse change in the
physical condition of the Property as described in the Property
Documents which would materially adversely affect Buyer's use and
occupancy of the Property; and

     c. Sellers' Performance. Sellers shall have performed all
of their obligations under this Agreement.

     10. No Encumbrance or Transfer. Except as provided herein,
Sellers shall not encumber, lease, transfer, assign or sell all or any
portion, or interest in, the Property or the Equipment, or enter into
any agreement or contract affecting or relating to the Property or the
Equipment without Buyer's prior written consent, which consent may be
withheld in Buyer's sole discretion.

     11. Escrow.

     a. Escrow. Within five (5) Business Days of the
Execution Date, Buyer shall establish an escrow ("Escrow") with the
Escrow Agent for the close of the subject transactions. An executed
copy of this Agreement shall be deposited with the Escrow Agent by
Buyer and this Agreement shall constitute Escrow Agent's escrow
instructions for closing Escrow. Escrow shall close ("Close of
Escrow") on or before the Closing Date.

     b. Sellers. On or prior to the Closing Date Sellers shall
deposit the following into Escrow:

        (i) Deed. A duly executed and acknowledged Deed in
usual form setting forth all exceptions to title created or suffered
by Mrs. Avery which are not to be removed at or prior to Closing;

        (ii) Non-Foreign Person Certificates. Duly
executed non-foreign person certificates ("Non-Foreign Person
Certificates") in usual form sufficient to relieve Buyer of any
withholding requirements pursuant to the provisions of Section 1445 of
the Internal Revenue Code of 1986 as amended (the "Code; and

        (iii) Bill of Sale. A Bill of Sale and assignment,
in a form reasonably approved by Buyer and Mr. Avery, of all of Mr.
Avery's rights, title, and interest in and to the Equipment and the
Intellectual Property (the "Bill of Sale"); and

        (iv) Additional Escrow Instructions and Documents.
Such additional escrow instructions ("Sellers' Additional Escrow
Instructions") and documents as Escrow Agent may reasonably require of
Sellers to close the sale of the Property and the Equipment in
accordance with this Agreement, which instructions shall not be
inconsistent with the terms of this Agreement.

     c. Buyer. On or prior to the Closing Date, Buyer shall
deposit the following into Escrow:

        (i) Note. The promissory note described hereinabove;

        (ii) Cash and Note. Cash in the amount
necessary to pay Buyer's share of closing costs and prorations, as
hereinafter set forth; and

        (iii) Additional Escrow Instructions
and Documents. Such additional escrow instructions ("Buyer's
Additional Escrow Instructions") and documents as Escrow Agent may
reasonably require of Buyer to close the sale of the Property and the
Equipment in accordance with this Agreement.

     12. Close of Escrow.

     a. Time. When the Escrow Holder has confirmed that
Title Company is in a position to issue an ALTA Extended Policy (Form
B-1970) ensuring title to the Property as being vested in Buyer in
accordance with Section 6(a) and all documents and funds required
hereby have been deposited with Escrow Agent, Escrow Agent shall cause
Close of Escrow to occur as provided below.

     b. Procedure. Escrow Agent shall close Escrow as follows:

        (i) Record the following documents in the order set forth below:

The Deed; and

The new second mortgage securing the Note.

         (ii) Deliver to Sellers the following:

           (1) The Note; and

           (2) A conformed copy of the Deed.

          (iii) Deliver to Buyer the following:

            (1) An ALTA Policy in accordance with Section 6(a);

            (2) The Non-Foreign Person Certificates; and

            (3) Conformed copies of the Deed and Note
                and the original of the Bill of Sale.

     c. Closing Costs and Prorations.

        (i) Closing Costs. Sellers shall pay
the cost for the Title Policy and all Endorsements. Sellers shall pay
county transfer taxes and one-half of the escrow fees applicable to
the sale. Buyer shall pay one-half of the escrow fees and all
recording fees attributable to the conveyance documents, and Sellers
shall pay indebtedness and recording fees attributable to the release
of any liens on the Property and the Equipment. All other costs and
charges of the escrow for the sale shall be paid in accordance with
local custom.

        (ii) Prorations. Real estate taxes and
all other expenses normal to the operation and maintenance of the
Property and the Equipment shall be prorated as of 12:01 a.m. on the
Closing Date.

        (iii) Escrow Cancellation Costs.
Notwithstanding the provisions of subsection (i) above, if Escrow
fails to close due to any Seller's default, such Seller shall pay all
Escrow cancellation charges. If Escrow fails to close due to Buyer's
default, Buyer shall pay all Escrow cancellation charges. If Escrow
fails to close for any reason other than the foregoing, Buyer and
Sellers shall each pay one-half (1/2) of any Escrow cancellation
charges. "Escrow cancellation charges" means all fees, charges, and
expenses incurred by Escrow Agent, including all expenses incurred in
connection with issuance of the Preliminary Report and other title matters.

     13. Brokers. Buyer and Sellers each represent to the other
parties that they have not engaged any broker or finder in connection
with any of the transactions contemplated by this Agreement. Buyer
shall indemnify, defend and hold Sellers harmless from and against any
loss, cost or expense, including, but not limited to, attorneys' fees
and court costs, resulting from any claim against Sellers for any fee
or commission by any broker or finder claiming by or through Buyer.
Sellers shall indemnify, defend and hold Buyer harmless from and
against any loss, cost or expense, including, but not limited to,
attorneys' fees and court costs, resulting from any claim for a fee or
commission by any broker or finder claiming by or through any Seller.
The covenants contained herein shall survive the Close of Escrow.

     14. Sellers' Representations, Warranties and Covenants.

     a. Sellers hereby make the following representations and
warranties to Buyer which representations and warranties shall survive
the Close of Escrow for a period of twelve (12) months (at which time
these representations and warranties shall expire):

        (i) Litigation; Government Action.
Except as disclosed to Buyer in writing, there is no claim,
litigation, or notice that the Property, the Equipment or the
Intellectual Property is in violation of any law, or that any
governmental investigation is presently pending with respect to which
any Seller has been served with process or other notice thereof or, to
the best of Sellers' knowledge, otherwise pending or threatened,
against or relating to the Property, the Equipment, or the
Intellectual Property. Except for the Assumed Liabilities, there is no
Liability which will become a Liability of Buyer following the Closing;

        (ii) Condemnation. There is presently
no pending condemnation of the Property or any part thereof with
respect to which any Seller has been served with process or other
notice thereof nor, to the best of Sellers' knowledge, is any such
condemnation otherwise pending or contemplated.

        (iii) Leases. There are no leases or
other occupancy agreements relating to the Property.

        (iv) Hazardous Materials.

          (1) For purposes hereof, "Hazardous
              Materials" shall mean any and all asbestos,
              radioactive material, hazardous waste, toxic
              substance or related material, including but
              not limited to those materials and substances
              defined as "hazardous substances", "hazardous
              materials", "hazardous wastes" or "toxic
              substances" in any Georgia or federal law or
              regulation.

          (2) Sellers have not released or discharged,
              or caused to be released or discharged, upon
              the Property any Hazardous Materials, and to
              the best of Sellers' knowledge there are no
              Hazardous Materials present on, in, or under
              the Property.

          (3) To the best of Sellers' knowledge, the
              Property Documents are all of the documents
              and reports in Sellers'  possession
              pertaining to Hazardous Materials on or at
              the Property.

        (v) Property Documents. There are no
other documents or reports in Sellers' possession or under Sellers'
control other than the Property Documents, describing the condition of
the Property or concerning the presence of Hazardous Materials, the
geotechnical condition of the soils, or other like physical condition
of the Property as of the Execution Date.

     b. Status and Authority. Mrs. Avery and Mr. Avery are
individual residents of the State of Georgia and Avery Georgia is a
corporation organized and in good standing in the State of Georgia,
and each has the power and authority to enter into this Agreement. No
other authorizations or approvals, whether of governmental bodies or
otherwise, will be necessary in order to enable Sellers to enter into
or to comply with the terms of this Agreement.

     c. Binding Effect of Documents. This Agreement and the
other documents to be executed by Sellers hereunder, upon execution
and delivery thereof by Sellers, will have been duly entered into by
Sellers, and will constitute legal, valid and binding obligations of
Sellers. Neither this Agreement nor anything provided to be done under
this Agreement, violates or shall violate any contract, document,
understanding, agreement, or instrument to which either Seller is a
party or by which they are bound.

     d. "Best Knowledge" Definition. For purposes of this
Section 11, the term "to the best of a Seller's knowledge" shall mean
current actual knowledge after usual inquiry in connection with the
operation of the Property, the Equipment, and the Intellectual
Property.

     e. "As-Is" Condition. Except as expressly provided in
this Agreement, Sellers make no representations or warranties of any
kind, express or implied, written or oral, as to the physical
condition of the Property and the Equipment; the uses thereof or any
limitations thereon, including, without limitation, zoning,
environmental or other laws, regulations or governmental requirements;
the utilities or other physical equipment and fixtures on the
Property, the costs of operating the Property or any other aspect of
the economic operations on the Property; the possibility of future
assessments of charges being levied against the Property or imposed as
a condition to development or construction; or the condition of the
soils or groundwater of the Property. Except as provided herein, Buyer
specifically acknowledges that it is acquiring the Property and the
Equipment in an "as-is" condition (as such term is most broadly
construed), in reliance upon its own inspection and investigation of
the Property and the Equipment.

     15. Loss by Fire or Other Casualty; Condemnation.

     a. Condemnation and General Casualty. Buyer shall be
bound to purchase the Property for the full Purchase Price as required
by the terms hereof, without regard to the occurrence or effect of any
damage to or destruction of the Equipment or any improvements or
condemnation of any portion of the Property. In the event of a
casualty, Buyer may elect to purchase the Property and the Equipment
pursuant to the terms of this sub-paragraph (a) or to require Sellers
to replace and/or repair the Equipment and to repair and complete the
Improvements pursuant to sub-paragraph (c). Such election shall be
made by written notice given within thirty (30) days following the
casualty. If Buyer elects to proceed pursuant to this sub-paragraph
(a), the Purchase Price shall be credited by the amount of any
insurance proceeds or condemnation awards (excluding proceeds or
awards payable in respect of carrying costs or other costs born by
Sellers and not subject to adjustment of the Purchase Price as
provided herein) collected by Sellers as a result of any such damage
or destruction or condemnation less any monies actually expended by
Sellers to repair any damage, plus any deductible amounts attributable
to such damage or destruction, or such proceeds shall be assigned to
Buyer if not then collected.

     b. Cooperation of Sellers. If Sellers assign the proceeds
of any insurance policy to Buyer pursuant to Section 12(a), Sellers
shall cooperate with Buyer in presenting and prosecuting the claim
with Sellers' insurance carriers, shall follow Buyer's instructions
with respect thereto (except to the extent Sellers are advised by
counsel that following a particular instruction would expose Sellers
to liability, or to the extent Sellers would incur additional cost to
follow such instruction which is not paid by Buyer), and will not
settle any such claim without Buyer's written approval.

     c. Insurance. Sellers shall purchase and keep in force a
policy or policies of fire and property damage insurance (including
coverage for flood and earthquake, if available) covering loss or
damage to the Property (including the improvements) and the Equipment
in the amount of the full replacement value thereof. In the event of a
casualty and election by Buyer (pursuant to sub-paragraph (a) above)
to require Sellers to replace the Equipment and to repair and complete
the Improvements, Sellers shall be obligated to do so pursuant to the
terms and conditions hereof subject to extension of all of the dates
for performance and the closing date for the delay caused by the
casualty. In such event there shall be no adjustment to the Purchase
Price for increase costs sustained by Sellers (whether or not such
costs are covered by insurance) in connection with or caused by the casualty.

     16. Successors and Assigns. The terms, covenants, and
conditions herein contained shall be binding upon and inure to the
benefit of the successors and assigns of the parties hereto.

     17. Entire Agreement. This Agreement contains all of the
covenants, conditions and agreements between the parties and shall
supersede all prior correspondence, agreements, and understandings,
both oral and written. No provisions of this Agreement may be amended
or modified in any manner except by an agreement in writing duly
executed by the parties hereto.

     18. Governing Law. This Agreement shall be governed by and
construed in accordance with the laws of the State of Georgia as
applied to agreements among Georgia residents which are entered into
and performed entirely within the State of Georgia.

     19. Attorneys' Fees; Arbitration.

     a. Attorneys' Fees. In the event of any litigation
or arbitration regarding the rights and obligations under this
Agreement, the prevailing party shall be entitled to recover, in
addition to damages, injunctive or other relief, reasonable attorneys'
fees, expert witness fees, and court costs.

     b. Arbitration of Disputes. ANY CONTROVERSY OR CLAIM
ARISING OUT OF THIS AGREEMENT SHALL BE SETTLED BY ARBITRATION IN
ACCORDANCE WITH THE RULES OF THE AMERICAN ARBITRATION ASSOCIATION FOR
THE ARBITRATION OF COMMERCIAL DISPUTES, AND JUDGMENT ON THE AWARD
RENDERED BY THE ARBITRATOR(S) MAY BE ENTERED IN ANY COURT HAVING
JURISDICTION. THE PREVAILING PARTY IN SUCH ARBITRATION SHALL BE
ENTITLED TO ATTORNEYS' FEES AND COSTS.

     20. Notices. All notices required or permitted to be
given pursuant to the terms hereof shall be in writing and either
delivered by hand delivery, professional courier service which
provides written evidence of delivery or  deposited in the United
States mail, registered or certified, postage prepaid and addressed as
follows:

To Sellers:

George Avery
Jural Avery
Avery Sports Turf, Inc.
#9 Industrial Park
Rome GA 30161

To Buyer:

Avery Sports Turf, Inc.
Attn: Gary Borglund
7550 24th Avenue South, Suite 168
Minneapolis MN 55450

The foregoing addresses may be changed by written notice to the other
party as provided herein. Notices shall be deemed delivered and
received, in the case of personal delivery or delivery by courier as
aforesaid, on the day physically delivered to the indicated addressee,
and in the case of delivery by United States mail, three (3) Business
Days after deposit in the United States mail as aforesaid.

      21. Exhibits. All of the following exhibits described in
this Agreement are incorporated herein by this reference and made a
part hereof:

Exhibit 1  Description of the Land
Exhibit 2  Description of the Equipment
Exhibit 3  Description of the Intellectual Property
Exhibit 4  Description of Assumed Liabilities
Exhibit 5  Description of Assumed Customer Contracts
Exhibit 6  Assignment of Intellectual Property
Exhibit 7  Description of the Excluded Assets
Exhibit 8  Description of the Excluded Liabilities
Exhibit 9  Form of the Note

     22. Purchase Price Allocation. The parties hereby agree that
the Purchase Price shall be allocated to the Acquired Assets and
Assumed Liabilities in the manner determined by Buyer. The Parties
covenant and agree to file all federal, state, and local Tax returns
in accordance with such allocations and to report the Closing as a
taxable transaction.

     23. Transfer Taxes. All transfer, gains, sales, bulk sales, use
and similar conveyance Taxes imposed by reason of the transactions
contemplated hereby and any deficiency, interest or penalty asserted
with respect thereto shall be paid in accordance with local law and custom.

     24. Authority. Each person executing this Agreement on
behalf of a party to this Agreement hereby represents and warrants
that he or she has authority to execute this Agreement on behalf of
such party.

     25. Headings. Headings at the beginning of any paragraph
or Section of this Agreement are solely for the convenience of the
parties and are not a part of this Agreement or to be used in the
interpretation hereof.

     26. Survival. The representations, warranties and
covenants of the parties hereto shall survive the Close of Escrow, or
the termination of the Agreement if the Close of Escrow does not
occur, subject to the express limitations on survivability contained
in this Agreement.

     27. Waiver. No waiver by Buyer or Seller of a breach of
any of the terms, covenants, or conditions of this Agreement by the
other party shall be construed or held to be a waiver of any
succeeding or preceding breach of the same or any other term, covenant
or condition herein contained. No waiver of any default by Buyer or
Seller hereunder shall be implied from any omission by the other party
to take any action on account of such default if such default persists
or is repeated, and no express waiver shall affect a default other
than as specified in such waiver. The consent or approval by Buyer or
a Seller to or of any act by the other party requiring the consent or
approval of the first party shall not be deemed to waive or render
unnecessary such party's consent or approval to or of any subsequent
similar acts by the other party.

     28. Confidentiality. Buyer and Sellers shall maintain this
Agreement in the terms and conditions of confidence except as required
by law and except as required in connection with the performance of
each of the obligations of Buyer and Sellers hereunder.
Notwithstanding anything to the contrary herein, the provisions of
this Section 25 shall be separate and severable from all of the other
provisions of this Agreement. A breach or alleged breach of the
provisions of this Section 25 shall not be grounds for termination of
this Agreement or otherwise excuse the performance of any other
obligations hereunder.

     29. Severability. If any phrase, clause, sentence, paragraph,
section, article, or other portion of this Agreement shall become
illegal, null or void or against public policy, for any reason, or
shall be held by any court of competent jurisdiction to be illegal,
null or void or against public policy, the remaining portions of this
Agreement shall not be affected thereby and shall remain in force and
effect to the fullest extent permissible by law.

     30. Counterparts. This Agreement may be executed in any
number of counterparts, each of which shall be deemed an original, and
all of which together shall constitute one and the same instrument.

     IN WITNESS WHEREOF, the parties hereto have executed this
Agreement as of the dates set forth next to their respective
signatures below.

BUYER:                                 Avery Sports Turf, Inc., a Nevada
                                       Corporation
                                       By: /s/  Gary Borglund
                                       Gary Borglund
                                       Its President

MRS. AVERY:                            /s/  Jural E. Avery
                                       Jural E. Avery

MR. AVERY:                             /s/George Avery
                                       George Avery

AVERY GEORGIA:                         AVERY SPORTS TURF, INC., A Georgia
                                       Corporation

                                       By: /s/  George Avery
                                       George Avery
                                       Its President

                                   EXHIBIT 1

                           [Description of Property]

     All of that tract or parcel of land situated, lying and being
in Land Lot 196 of the 23rd District and 3rd Section of Floyd County,
Georgia, and being Tract 9 of Riverside Industrial Park, formerly the
property of Celanese Fibers Company, and being more particularly
described as follows:

     BEGINNING at a point formed by the NW intersection
Of Celanese Drive and Riverside Industrial Drive West; thence
S 88 degrees 2 min W 468.95 feet along the northern right of
Way of Celanese Drive to a point; thence N 2 degrees 03 minutes
36 seconds W 330.7 feet to a point; thence N 88 degrees 5 minutes
E 469.78 feet to a point on the western right of way of Riverside
Industrial Drive West; thence S 1 degree 55 minutes E 330.29 feet along
the western right of way of Riverside Industrial Drive West to the POINT
OF BEGINNING.

                                      EXHIBIT 2

                             [Description of the Equipment]

Quantity        Description

  One           CTS SN 3502070 Remfg No 2539

  One           Model 1973 15' Tufting Machine
                w/ access. and motors

  One           Tufting Machine and motors

  Two           Double desk creel with nylon tubing And decking

  Two           mending gun assembly

                                    EXHIBIT 3

                  [Description of the Intellectual Property]

     All of Mr. Avery's and Avery Georgia's right, title and
interest in and to, the following patents (including any reissues,
continuations-in-part, revisions, extensions, and reexaminations
thereof), all related documentation, including, without limitation,
all related copyrights, if any, and the exclusive right to enforce the
Patents in the United States and throughout the world in the sole name
of Buyer, its successors or assigns, including all rights to profits
and damages by reason of past infringement by any party or parties,
including the right to sue and collect same for Buyer's and Buyer's
successors and assigns own use and benefit, free and clear of any and
all liens, encumbrances, or third party claims.

Quantity          Description

  One(1)          Invention entitled "Artificial Turf with
                  Granule Retaining Fibers, for which an
                  Application for Letters Patent of the
                  United States was filed in the United
                  States Patent and Trademark Office on
                  December 10, 2003, under Serial No. 10/733,806

                               EXHIBIT 4

              [Description of the ASSUMED LIABILITIES]

Existing first mortgage indebtedness ("Bank Debt") encumbering the
Property, with a remaining balance due as of the date of this
Agreement of approximately Two Hundred Fifteen Thousand Dollars
($215,000).

                                   EXHIBIT 5

                [Description of the ASSUMED CUSTOMER CONTRACTS]

[See Attached schedule, consisting of 3 pages, incorporated herein by
reference]

                                    EXHIBIT 6

                                   ASSIGNMENT

     WHEREAS, George S. Avery and/or Avery Sports Turf, Inc., a
Georgia corporation ("Assignors"), own or have rights to the Invention
(the "Invention") entitled "Artificial Turf with Granule Retaining
Fibers, for which an Application for Letters Patent of the United
States was filed in the United States Patent and Trademark Office on
December 10, 2003, under Serial No.10/733,806; and

     WHEREAS, Avery Sports Turf, Inc., a Delaware corporation
("Assignee"), wishes to acquire full rights and ownership of such
Invention.

     NOW THEREFORE, for good and valuable consideration, the
receipt and sufficiency of which are hereby acknowledged, Assignors
hereby grant, convey, assign and transfer to the Assignee and the
Assignee's successors and assigns, Assignors' entire right, title and
interest in and to such Invention, including all corresponding
applications such as continuations, continuations-in-part,
divisionals, provisionals, renewals, revivals, reissues,
reexaminations, extensions, and foreign counterparts thereof, along
with the subject matter of any and all claims which may be obtained in
the aforementioned, in the United States and every foreign country,
including all rights to profits and damages by reason of past
infringement by any party or parties, either the right to sue and
collect same for Assignee's, and Assignee's successors and assigns own
use and benefit.

     UPON SAID CONSIDERATION, Assignors appoint Assignee and
Assignee's successors and assigns as their attorney-in-fact to act in
Assignors' names and places, to execute, deliver and record any
document or instrument of assignment or conveyance necessary to
perfect, grant and confirm the rights granted herein, and Assignors
hereby further convey to the Assignee the right to make application
in, prosecute, receive and enforce in their own behalf and name such
Invention.

     IN WITNESS WHEREOF, Assignors have caused this Assignment to
be duly executed on the date shown below.

AVERY SPORTS TURF, INC.

By: /s/  George Avery                       /s/  George S. Avery
George Avery, President                     George S. Avery

DATE: 12-19-2003                            DATE: 12-19-2003

                                 EXHIBIT 7

                    [Description of the EXCLUDED ASSETS]

There shall be excluded from the definition of Acquired Assets, and
there shall be no conveyance, sale, transfer, assignment or delivery
to Buyer of:

     1. Any Inventory or other assets disposed of by Mr. Avery or
Avery Georgia between the Execution Date and the Closing Date in the
ordinary course of business consistent with this Agreement;

     2. Any Accounts Receivable liquidated by Mr. Avery or Avery
Georgia between the Execution Date and the Closing Date in the
ordinary course of business consistent with this Agreement;

     3. All capital stock of Avery Georgia;

     4. Mr. Avery's rights under U.S. Patent No. 5,976,645; and

     5. All consideration to be received by Sellers in the
transactions contemplated by this Agreement.

                               EXHIBIT 8

              [Description of the EXCLUDED LIABILITIES]

     1. Except as expressly provided to the contrary in Section 5 of
the Agreement, Buyer shall not by the execution and performance of the
Agreement, or otherwise under any circumstance, assume or otherwise be
responsible for any Liability or obligation of any nature of Sellers,
or Claims of such Liability or obligation, including, without
limitation, those arising from: (a) all Taxes of any kind whatsoever
arising from the Acquired Assets or operation of the Business, but
only to the extent attributable to any Tax Period prior to the
Closing; (b) any occurrence or circumstance (whether known or unknown)
which occurs or exists prior to the Closing Date and which
constitutes, or which by the lapse of time or delivery of notice (or
both) would constitute, a breach or default under any Customer
Contracts (whether written or oral); (c) any occurrence or
circumstance (whether known or unknown) which occurs or exists prior
to the Closing Date and which constitutes, or which by the lapse of
time or delivery of notice (or both) would constitute, a violation of
the requirements of any Governmental Authority or of the rights of any
third person, including, without limitation, requirements relating to
the reporting or payment (or both) of federal, state, local or foreign
income, property or other Taxes; (d) Indebtedness of Sellers; (e) any
environmental, Liabilities for death or      destruction of property
or any Liabilities for breach of warranties of Sellers in the sale and
distribution of Products or any Liabilities for acts or omissions of
Sellers or their employees prior to the Closing Date, in each case
arising from events or occurrences which occurred prior to the Closing Date;

     2. Any Liabilities accruing on or prior to the Closing relating
to Sellers' employment or termination of Sellers' employees that are
not Assumed Liabilities;

     3. Any Liability arising out of any litigation pending on the
Closing Date, whether or not disclosed to Buyer; and

     4. Any other Claims of any kind whatsoever or any other
Liabilities of Sellers, direct or indirect.

The Parties agree that Buyer shall not be construed as the successor
of any of the Sellers, and Sellers shall retain, pay, perform and
discharge such Excluded Liabilities.

                                  EXHIBIT 9

                              [Form of the NOTE]

                               PROMISSORY NOTE

$200,000                                                December 19, 2003

    FOR VALUE RECEIVED, the undersigned, Avery Sports Turf, Inc., a
Delaware corporation ("Maker"), hereby promises to pay to the order of
George S. Avery, an individual residing in the State of Georgia,
("Payee"), in lawful money of the United States of America, the
principal sum of Two Hundred Thousand Dollars ($200,000) in seven
installments, in the following amounts and at the following times:

Installment Due Date                 Principal Installment Amount

March 31, 2004                       Twenty-five Thousand Dollars (25,000.00)
June 30, 2004                        Twenty-five Thousand Dollars (25,000.00)
September 30, 2004                   Twenty-five Thousand Dollars (25,000.00)
March 31, 2005                       Twenty-five Thousand Dollars (25,000.00)
June 30, 2005                        Twenty-five Thousand Dollars (25,000.00)
September 30, 2005                   Twenty-Five Thousand Dollars (25,000.00)
March 30, 2006                       Fifty Thousand Dollars (50,000.00)

     No interest shall accrue or be due on this note.

     This note may be prepaid in whole or in part, without premium,
penalty or discount, at any time, or from time to time, at the option
of the undersigned.

     The occurrence of any of the following events shall constitute
an Event of Default under this note:

     (a)  the undersigned shall fail to make any payment of
principal due hereunder for more than fifteen business days after the
due date thereof;

     (b)  the undersigned shall commence any case or proceeding
seeking to have an order for relief entered on its behalf as debtor or
to adjudicate it as bankrupt or insolvent or seeking reorganization,
liquidation, dissolution, winding-up, arrangement, composition or
readjustment of its debts or any other relief under any bankruptcy,
insolvency, reorganization, liquidation, dissolution, arrangement,
composition, readjustment of debt or other similar act or law of any
jurisdiction, domestic or foreign, now or hereafter existing; or the
undersigned shall apply for a receiver, custodian or trustee (other
than any trustee appointed as a mortgagee or secured party in
connection with the issuance of indebtedness for borrowed money of the
undersigned) of it or for all or a substantial part of its property;
or the undersigned shall make a general assignment for the benefit of
creditors; or the undersigned shall take any corporate action in
furtherance of any of the foregoing; or

     (c)  an involuntary case or other proceeding shall be commenced
against the   undersigned with respect to it or its debts
under any bankruptcy, insolvency or other similar law now or hereafter
in effect seeking the appointment of a trustee, receiver, liquidator,
custodian or similar official of it or any substantial part of its
property; and such case or proceeding (i) results in the entry of an
order for relief or a similar order against it or (ii) shall continue
unstayed and in effect for a period of 60 consecutive days.

     Upon the occurrence of an Event of Default, the unpaid
principal balance of this note shall become immediately due and
payable, without presentment, demand, protest or other formalities of
any kind, all of which are hereby expressly waived by the undersigned.

     The substantive laws of the State of Georgia shall govern the
validity, construction, enforcement and interpretation of this note.
In the event of a dispute involving this note or any other instruments
executed in connection herewith, the undersigned irrevocably agrees
that venue of such dispute shall lie exclusively in any court of
competent jurisdiction in the County of Floyd, Georgia.

     This Note is secured by a second mortgage of even date,
encumbering the interest of Maker in real property located at 9
Riverside Industrial Park, Rome, Georgia, the terms and conditions of
which are incorporated herein by reference.

                                       AVERY SPORTS TURF, INC.

                                       By: /s/  Gary Borglund
                                       Gary Borglund
                                       Its: President

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00065-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00065-of-00352.parquet"}]]