Document:

EX-10.4

 Exhibit 10.4 
 REDWOOD BUSINESS CENTER 
 FULL SERVICE LEASE 

BASIC LEASE INFORMATION 
  

			
	DATE:	  	July 2, 2013
		
	LANDLORD:	  	REDWOOD BUSINESS CENTER 1 LLC, a California limited liability company and AMERIVINE TOWN CENTER, LLC, a California limited liability company
		
	LANDLORD’S ADDRESS:	  	 c/o Basin Street Properties

119 C Street
 Petaluma, CA 94952

Attn: Scott W. Stranzl
 Phone:(707)
795-4477
 Fax:(707) 795-6283

		
	TENANT:	  	CYAN, INC., a Delaware corporation doing business in California as Cyan California
		
	TENANT’S ADDRESS:	  	
		
	 a. Before Commencement Date:
	  	1383 North McDowell Boulevard, Suite 300 Petaluma, CA 94954, Attn: General Counsel
		
	 b. After Commencement Date:
	  	Same
		
	PREMISES:	  	The entire third floor of the Building (the
“3rd Floor Premises”) consisting of
approximately 20,005 rentable square feet of space (including the bridge between the Building and the adjacent building located at 1383 N. McDowell Blvd.) and, after the 2nd Floor Rent Commencement, the entire second floor of the Building (the “2nd Floor Premises”), consisting of approximately 18,773 rentable
square feet per floor, for a total of 38,778 rentable square feet.
		
	BUILDING:	  	That certain office building to be constructed within the Project, having an address of 1385 McDowell Blvd. and consisting of approximately 57,438 rentable square feet of
space.
		
	PROJECT:	  	That certain business center located in Petaluma, California, and commonly referred to as “Redwood Business Center” and consisting of approximately 155,984 rentable
square feet of space once the Building is constructed.
		
	TERM:	  	Ten (10) years
		
	 a. Commencement Date
	  	See Section 3.1.
		
	 b. Estimated Commencement Date
	  	June 1, 2014
		
	BASE RENT:	  	
		
	 a. Initial Monthly Base Rent
	  	Forty Six Thousand One Hundred Eleven and 90/100 Dollars ($46,011.50)
		
	 b. Adjustment Date of Monthly Base Rent
	  	See Addendum

  
 i 

			
	BASE YEAR	  	The calendar year in which the Commencement Date occurs.
		
	TENANT’S BUILDING PERCENTAGE SHARE:	  	Initially 34.83% (20,005 r.s.f./57,438 r.s.f.); increasing to 67.51% (38,778 r.s.f./57,438 r.s.f.) upon 2nd Floor Rent Commencement pursuant to Section27.
		
	TENANT’S PROJECT PERCENTAGE SHARE:	  	Initially 12.83%% (20,005/155,984); increasing to 24.86% (38,778/155,984) upon 2nd Floor Rent Commencement pursuant to Section27.
		
	SECURITY DEPOSIT:	  	Forty Six Thousand One Hundred Eleven and 90/100 Dollars ($46,011.50)
		
	PERMITTED USE:	  	For use as office, research and development and laboratory with rack mounted electronic equipment and environmental chamber and for no other use or purpose.
		
	PARKING SPACES:	  	Tenant shall have the right to use 3.8 spaces per 1,000 usable square feet of the Premises on an unreserved basis in the parking areas shown on Exhibit A-2.
		
	REAL ESTATE BROKERS:	  	
		
	 a. Landlord’s Broker:
	  	N/A
		
	 b. Tenant’s Broker:
	  	N/A
		
	GUARANTOR:	  	
		
	 Name:
	  	N/A
		
	 Address:
	  	N/A
		
	EXHIBITS AND ADDENDUM	  	

  

			
	Addendum:	  	Four (4) pages
		
	Exhibit A-1:	  	Diagram of Premises
	Exhibit A-2:	  	Diagram of Project
	Exhibit B-1:	  	Work Letter Agreement—3rd Floor
	Exhibit B-2:	  	Work Letter Agreement—2nd Floor
	Exhibit C:	  	Commencement Date Memorandum
	Exhibit D:	  	Rules and Regulations

  
 ii 

 REDWOOD BUSINESS CENTER 

FULL SERVICE LEASE 
 THIS REDWOOD BUSINESS CENTER FULL SERVICE LEASE (this “Lease”) dated as of July 2, 2013, is entered into by and between REDWOOD BUSINESS CENTER 1 LLC, a California limited liability
company and AMERIVINE TOWN CENTER, LLC, a California limited liability company (collectively, “Landlord”), and CYAN, INC., a Delaware corporation doing business in California as Cyan California (“Tenant”). 

1. Definitions. The following terms shall have the meanings set forth below: 

1.1. Building. The term “Building” shall have the meaning set forth in the Basic Lease Information. 

1.2. Building Common Areas. The term “Building Common Areas” shall mean the areas and facilities within the Building
provided and designated by Landlord for the general use, convenience or benefit of Tenant and other tenants and occupants of the Building (e.g., common stairwells, stairways, hallways, shafts, elevators, restrooms, janitorial telephone and
electrical closets, pipes, ducts, conduits, wires and appurtenant fixtures servicing the Building). 
 1.3. Commencement
Date. The term “Commencement Date” shall have the meaning set forth in the Basic Lease Information. 
 1.4.
Common Areas. The term “Common Areas” shall mean the Building Common Areas and the Project Common Areas. 

1.5. Premises. The term “Premises” shall have the meaning set forth in the Basic Lease Information. 

1.6. Project. The term “Project” shall have the meaning set forth in the Basic Lease Information. 

1.7. Project Common Areas. The term “Project Common Areas” shall mean the areas and facilities within the Project
provided and designated by Landlord for the general use, convenience or benefit of Tenant and other tenants and occupants of the Project (e.g., walkways, parking lots, driveways, traffic aisles, accessways, utilities and communications conduits and
facilities). 
 1.8. Rentable Area. The term “Rentable Area” shall mean the rentable area of the Premises,
Building and Project as reasonably determined by Landlord. The parties agree that for all purposes under this Lease, the Rentable Area of the Premises, Building and Project shall be deemed to be the number of rentable square feet identified in the
Basic Lease Information. 
 1.9. Tenant’s Building Percentage Share. The term “Tenant’s Building
Percentage Share” shall mean the percentage specified in the Basic Lease Information. If the Rentable Area of the Premises or the Rentable Area of the Building is changed due to a change in the actual size thereof, then Tenant’s Building
Percentage Share shall be adjusted to a percentage equal to the Rentable Area of the Premises divided by the Rentable Area of the Building. 
 1.10. Tenant’s Project Percentage Share. The term “Tenant’s Project Percentage Share” shall mean the percentage specified in the Basic Lease Information. If the Rentable Area of
the Premises or the Rentable Area of the Project is changed due to a change in the actual size thereof, then Tenant’s Project Percentage Share shall be adjusted to a percentage equal to the Rentable Area of the Premises divided by the Rentable
Area of the Project. 
 1.11. Term. The term “Term” shall have the meaning set forth in the Basic Lease
Information. 

  
 1 

 2. Premises. 

2.1. Demise. Landlord hereby leases to Tenant, and Tenant hereby leases from Landlord, for the Term, at the rent and upon the
conditions set forth below, the Premises, together with the right in common with other Building occupants to use the Building Common Areas and other Project occupants to use the Project Common Areas. 

2.2. Intentionally Deleted. 
 2.3. Reserved Rights. Provided the following actions do not unreasonably interfere with Tenant’s access to the Premises or Tenant’s parking rights, Landlord reserves the right to do the
following from time to time: 
 (a) Changes. To install, use, maintain, repair, replace and relocate pipes, ducts,
shafts, conduits, wires, appurtenant meters and mechanical, electrical and plumbing equipment and appurtenant facilities for service to other parts of the Building or Project above the ceiling surfaces, below the floor surfaces and within the walls
of the Premises and in the central core areas of the Building and in the Building Common Areas, and to install, use, maintain, repair, replace and relocate any pipes, ducts, shafts, conduits, wires, appurtenant meters and mechanical, electrical and
plumbing equipment and appurtenant facilities servicing the Premises, which are located either in the Premises or elsewhere outside of the Premises; 
 (b) Boundary Changes. To change the boundary lines of the Project; 
 (c)
Facility Changes. To alter or relocate the Common Areas or any facility within the Project; 
 (d) Parking. To
designate and/or redesignate specific parking spaces in the Project for the exclusive or non-exclusive use of specific tenants in the Project; 
 (e) Services. To install, use, maintain, repair, replace, restore or relocate public or private facilities for communications and utilities on or under the Building and/or Project; and 

(f) Other. To perform such other acts and make such other changes in, to or with respect to the Common Areas, Building and/or
Project as Landlord may reasonably deem appropriate. 
 2.4. Work Letter Agreements. Landlord and Tenant shall each
perform the work required to be performed by it as described in the Work Letter Agreements attached hereto as Exhibit B-1 and Exhibit B-2. Landlord and Tenant shall each perform such work in accordance with the terms and conditions contained
therein. 
 3. Term. 

3.1. Commencement Date. The Term shall be for the period of time specified in the Basic Lease Information
unless sooner terminated as hereinafter provided. The Term shall commence on the date the 3rd Floor Premises are delivered to the Tenant in the condition required herein and with the Tenant Improvements and Tenant Extra Improvements therein and Building Common Areas and bridge (including all
systems serving the Building Common Areas, bridge and the Premises) in “substantially completed” condition (as defined in the Work Letter Agreement—3rd Floor), subject to adjustment for “Tenant Delays” as provided in the Work Letter Agreement—3rd Floor but in no event prior to the Warm Shell Completion Date (as so
adjusted, the “Commencement Date”) and shall continue thereafter in full force and effect for the period specified as the Term or until this Lease is terminated as otherwise provided herein. For purposes of this Lease, the first
“Lease Year” shall mean the period commencing on the Commencement Date and ending twelve (12) months thereafter, except that if the Commencement Date is other than the first day of a calendar month, the first “Lease Year”
shall mean the period commencing on the Commencement Date and ending on the last day of the twelfth (12th) full calendar month after the Commencement Date. Thereafter, the term “Lease Year” shall mean a period equal to twelve (12) full calendar months. 

3.2. Delay in Delivery. Landlord shall deliver possession of the Premises to Tenant in good, vacant, broom clean condition, with
the Tenant Improvements and Tenant Extra 

  
 2 

 
Improvements and Building Common Area and bridge, including Building systems serving all of the foregoing, substantially completed, and in compliance with all laws. If for any reason Landlord has
not delivered to Tenant possession of the Premises by the Estimated Commencement Date, this Lease shall remain in effect and Landlord shall not be liable to Tenant for any loss or damage resulting therefrom. Notwithstanding the foregoing, if
(a) Landlord has not received all permits to construct the Building, the Tenant Improvements and Tenant Extra Improvements and received design review approval for the bridge by December 1, 2013, (b) Landlord has not commenced
construction of the Building (beyond the pad or other work that has been completed prior to the date hereof) by January 1, 2014, (c) Landlord has not received all permits to construct the bridge by March 1, 2014, or (d) the
Commencement Date has not occurred on or before March 1, 2015, then, as Tenant’s sole and exclusive remedy, Tenant may terminate this Lease by written notice to Landlord given prior to the satisfaction of the applicable condition,
whereupon any monies previously paid by Tenant to Landlord shall be reimbursed to Tenant. The foregoing dates shall be extended one day for each day that Landlord is delayed in completing the requirements to meet the above conditions due to Tenant
Delay and one day for each day after June 14, 2013 until Tenant submits this Lease to Landlord fully executed by Tenant. 

3.3. Commencement Date Memorandum. Following the date on which Landlord delivers possession of the Premises to Tenant and the
Commencement Date, Landlord may prepare and deliver to Tenant a commencement date memorandum (the “Commencement Date Memorandum”) in the form of Exhibit C, attached hereto, subject to such changes in the form as may be required to
insure the accuracy thereof. The Commencement Date Memorandum shall certify the date on which Landlord delivered possession of the Premises to Tenant and the dates upon which the Term commences and expires. Tenant’s failure to execute and
deliver to Landlord the Commencement Date Memorandum within ten (10) days after Tenant’s receipt of the Commencement Date Memorandum shall be conclusive upon Tenant as to the matters set forth in the Commencement Date Memorandum.

 4. Rent. 
 4.1. Base Rent. For purposes of this Lease, the term “Rent” shall mean the Base Rent, all additional rent, and all of the other monetary obligations of Tenant under this Lease. Tenant
shall pay to Landlord the Base Rent specified in the Basic Lease Information, in advance, on or before the first day of each and every calendar month commencing on the Commencement Date. If the Term commences on other than the first day of a
calendar month, the first payment of Base Rent shall be appropriately prorated on the basis of the number of days in such calendar month. If the Term expires on other than the last day of a calendar month, the last payment of Base Rent shall be
appropriately prorated based on the number of days in such calendar month. 
 4.2. Adjustments to Base Rent. The Base
Rent shall be adjusted as provided in the Addendum attached hereto. 
 4.3. Additional Rent. Commencing on the
Commencement Date, Tenant shall pay, as additional rent, all amounts of money that Tenant is required to pay to Landlord under this Lease in addition to monthly Base Rent whether or not the same is designated “additional rent.” Tenant
shall pay to Landlord all additional rent upon Landlord’s written request or otherwise as provided in this Lease. 
 4.4.
Late Payment. Tenant acknowledges that late payment of Rent to Landlord will cause Landlord to incur costs not contemplated by this Lease, the exact amount of which is extremely difficult to ascertain. Such costs include, but are not limited
to, processing and accounting charges and late charges which may be imposed on Landlord by the terms of any trust deed covering the Premises. Accordingly, if any installment of Rent or any other sums due from Tenant shall not be received by Landlord
within five (5) days of when due, Tenant shall pay to Landlord a late charge in an amount equal to five percent (5%) of such overdue amount. The parties agree that such late charge represents a fair and reasonable estimate of the costs
Landlord will incur by reason of late payment by Tenant. Acceptance of such late charge by Landlord shall not constitute a waiver of Tenant’s default with respect to such overdue amount, nor prevent Landlord from exercising any of the other
rights and remedies granted hereunder. Notwithstanding anything to the contrary herein, before assessing a late charge or late interest the first time in any one (1) year period, Landlord shall provide Tenant written notice of the delinquency,
and shall waive such late charge and late interest if Tenant pays such delinquency within five (5) days thereafter. 

  
 3 

 4.5. Interest. In addition to the imposition of a late payment charge pursuant to
Section 4.4 above, any Rent that is not paid within five (5) days of when due shall bear interest from the date due until paid at the rate that is the lesser of eight percent (8%) per annum (the “Interest Rate”) or the
maximum rate permitted by law. Payment of interest shall not excuse or cure any default hereunder by Tenant. 
 4.6.
Payment. All payments due from Tenant to Landlord hereunder shall be made to Landlord without deduction or offset, in lawful money of the United States of America at Landlord’s address for notices hereunder, or to such other person or at
such other place as Landlord may from time to time designate in writing to Tenant. 
 5. Taxes. 

5.1. Tenants Obligations. Tenant shall pay to Landlord, as additional rent, Tenant’s Building Percentage Share of any
increase in Taxes over the Base Taxes during each year of the Term (prorated for any partial calendar year during the Term). The term “Base Taxes” shall mean those taxes incurred by Landlord during the calendar year specified as the Base
Year in the Basic Lease Information. 
 5.2. Definition of Taxes. The term “Taxes” shall include all transit
charges, housing fund assessments, real estate taxes and all other taxes relating to the Premises, Building and Project of every kind and nature whatsoever, including any supplemental real estate taxes attributable to any period during the Term; all
taxes which may be levied in lieu of real estate taxes; and all assessments, assessment bonds, levies, fees, penalties (if a result of Tenant’s delinquency) and other governmental charges (including, but not limited to, charges for parking,
traffic and any storm drainage/flood control facilities, studies and improvements, water and sewer service studies and improvements, and fire services studies and improvements); and all amounts necessary to be expended because of governmental
levies, whether general or special, ordinary or extraordinary, unforeseen as well as foreseen, of any kind and nature for public improvements, services, benefits or any other purpose, which are assessed, based upon the use or occupancy of the
Premises, Building and/or Project, or levied, confirmed, imposed or become a lien upon the Premises, Building and/or Project, or become payable during the Term, and which are attributable to any period within the Term. 

5.3. Limitation. Nothing contained in this Lease shall require Tenant to pay any franchise, estate, inheritance, succession or
transfer tax of Landlord, or any income, profits or revenue tax or charge upon the net income of Landlord from all sources. In addition, notwithstanding anything herein to the contrary, “Taxes” shall not include and Tenant shall not be
required to pay any portion of any tax or assessment expense or any increase therein (a) levied on Landlord’s rental income, unless such tax or assessment is imposed in lieu of real property taxes; (b) imposed on land and improvements
other than the Project; (c) attributable to Landlord’s gift or state taxes; or (d) resulting from the improvement of any of the Project for the sole use of other occupants to the extent such improvements exceed the value of typical
improvements in the Project. In addition, (i) Taxes shall not include any amounts otherwise included as Taxes that relate solely to another building or buildings in the Project, (ii) Taxes that relate to more than just the Building may be
included in Taxes only to the extent reasonably allocable to the Building and (iii) if Base Taxes are not based on a fully completed and assessed Building, Base Taxes shall be increased to reflect a fully completed and assessed Building.

 5.4. Installment Election. In the case of any Taxes which may be evidenced by improvement or other bonds or which may
be paid in annual or other periodic installments, Landlord shall elect to cause such bonds to be issued or such assessment to be paid in installments over the maximum period permitted by law. 

5.5. Estimate of Tenant’s Share of Taxes. Prior to the commencement of each calendar year during the Term, or as soon
thereafter as reasonably practicable, Landlord shall notify Tenant in writing of Landlord’s estimate of the amount of Taxes which will be payable by Tenant for the ensuing calendar year. On or before the first day of each month during the
ensuing calendar year, Tenant shall pay to Landlord in advance, together with Base Rent, one-twelfth (1/12th) of the estimated amount; provided, however, if Landlord fails to notify Tenant of 

  
 4 

 
the estimated amount of Tenant’s share of Taxes for the ensuing calendar year prior to the end of the current calendar year, Tenant shall be required to continue to pay to Landlord each
month in advance Tenant’s estimated share of Taxes on the basis of the amount due for the immediately prior month until thirty (30) days after Landlord notifies Tenant of the estimated amount of Tenant’s share of Taxes for the ensuing
calendar year. If at any time it appears to Landlord that Tenant’s share of Taxes payable for the current calendar year will vary from Landlord’s estimate, Landlord may give notice to Tenant of Landlord’s revised estimate for the
year, and subsequent payments by Tenant for the year shall be based on the revised estimate. 
 5.6. Annual Adjustment.
Within one hundred twenty (120) days after the close of each calendar year during the Term, or as soon after the one hundred twenty (120) day period as reasonably practicable, Landlord shall deliver to Tenant a statement of the adjustment
to the Taxes for the prior calendar year. If, on the basis of the statement, Tenant owes an amount that is less than the estimated payments for the prior calendar year previously made by Tenant, Landlord shall apply the excess to the next payment of
Rent due. If, on the basis of the statement, Tenant owes an amount that is more than the amount of the estimated payments made by Tenant for the prior calendar year, Tenant shall pay the deficiency to Landlord within thirty (30) days after
delivery of the statement. The year-end statement shall be binding upon Tenant unless Tenant notifies Landlord in writing of any objection thereto within one hundred eighty (180) days after Tenant’s receipt of the year end statement. In
addition, if, after the end of any calendar year or any annual adjustment of Taxes for a calendar year, any Taxes are assessed or levied against the Premises, Building or Project that are attributable to any period within the Term (e.g.,
supplemental taxes or escaped taxes), Landlord shall notify Tenant of its share of such additional Taxes and Tenant shall pay such amount to Landlord within thirty (30) days after Landlord’s written request therefor. 

5.7. Personal Property Taxes. Tenant shall pay or cause to be paid, not less than ten (10) days prior to delinquency, any and
all taxes and assessments levied upon all of Tenant’s trade fixtures, inventories and other personal property in, on or about the Premises. When possible, Tenant shall cause Tenant’s personal property to be assessed and billed separately
from the real or personal property of Landlord. On request by Landlord, Tenant shall furnish Landlord with satisfactory evidence of payment of Tenant’s business personal property taxes and deliver copies of such business personal property tax
bills to Landlord. 
 5.8. Taxes on Tenant Improvements. Notwithstanding any other provision hereof, Tenant shall pay to
Landlord the full amount of any increase in Taxes during the Term resulting from any and all alterations of any kind whatsoever placed in, on or about or made to the Premises, Building or Project for Tenant that exceed the value of typical
improvements in the Project, other than the Tenant Improvements and Tenant Extra Improvements, which shall be included in Base Taxes. 
 6. Operating Expenses. 
 6.1. Obligation to Pay Operating
Expenses. Operating Expenses at the level incurred for the Base Year are included in the Base Rent for each calendar year of the Term. Commencing with the first calendar month following the Base Year, Tenant shall pay to Landlord as additional
rent during the Term (i) Tenant’s Building Percentage Share of any increase in Operating Expenses allocated to the ownership, operation, repair and/or maintenance of the Building over the Base Operating Expenses allocated to the Building
and (ii) Tenant’s Project Percentage Share of any increase in Operating Expenses allocated to the ownership, repair and maintenance of the Project over the Base Operating Expenses for the Project, as reasonably determined by Landlord;
provided that Landlord has the right to allocate any Operating Expenses incurred in connection with the ownership, operation, repair and/or maintenance of the Project to one or more particular buildings within the Project and at such ratios
as Landlord reasonably determines based upon the nature of the Operating Expense; and provided further that any Operating Expense that is solely related to a single Building shall be allocated solely to such Building. The term “Base
Operating Expenses” shall mean those Operating Expenses incurred by Landlord during the calendar year specified as the Base Year in the Basic Lease Information. 
 6.2. Definition of Operating Expenses. The term “Operating Expenses” shall include all expenses and costs of every kind and nature which Landlord shall pay or become obligated to pay
because of or in connection with the ownership, operation, repair and/or 

  
 5 

 
maintenance of the Building, Common Areas and/or Project, and the supporting facilities, including, without limitation: (A) all maintenance, janitorial and security costs, (B) costs for
all materials, supplies and equipment; (C) all costs of water, heat, gas power, electricity, refuse collection, parking lot sweeping, landscaping, and other utilities and services provided or allocated to the Building and the Common Areas;
(D) all property management expenses, including, without limitation, all property management fees and all expense and cost reimbursements, (E) all costs of alterations or improvements to the Building or Common Areas made to achieve
compliance with federal, state and local law including, without limitation, the Americans with Disabilities Act (42 U.S.C. Section 12101 et seq.), or to reduce Operating Expenses or improve the operating efficiency of the Building or the
Project, all of which costs will be amortized over the useful life of such alteration or improvement as reasonably determined by Landlord, together with interest upon the unamortized balance at the Interest Rate or such other higher rate as may have
been paid by Landlord on funds borrowed for the purpose of making the alterations or improvements; (F) premiums for insurance maintained by Landlord pursuant to this Lease or with respect to the Building and the Project; (G) costs for
repairs, replacements, and general maintenance of the Building, Common Areas and Project, but excluding any repairs or replacements paid for out of insurance proceeds or by other parties; (H) all costs incurred by Landlord for making any
capital improvements or structural repairs to the Building or the Common Areas, which costs will be amortized over the useful life of such improvement, repair or modification, as reasonably determined by Landlord, together with interest upon the
unamortized balance at the Interest Rate or such other higher rate as may have been paid by Landlord on funds borrowed for the purpose of constructing the improvements or making the improvements or repairs; (I) all costs of maintaining
machinery, equipment and directional signage or other markers; and (J) the share allocable to the Building of dues and assessments payable under any reciprocal easement or common area maintenance agreements or declarations or by any owners
associations affecting the Building or the Project. Notwithstanding the foregoing, the amount of Controllable Operating Expenses (defined below) payable by Tenant pursuant to Section 6.1 above during the initial Term shall not increase by more
than three percent (3%) per calendar year on a cumulative basis. For purposes of this Lease, the term “Controllable Operating Expenses” shall mean and include all Operating Expenses other than Taxes, insurance and utilities.
Notwithstanding anything in this Lease to the contrary, “Operating Expenses” shall also not include all or any portion of the following: (a) costs occasioned by casualties or condemnation; (b) costs to correct any construction
defect in the Project or to correct any violation of any covenant, condition, restriction, underwriter’s requirement or law applicable to the Project on the Commencement Date; (c) costs of the initial construction of the Building or any
renovation, improvement, painting or redecorating of any portion of the Project not made available for Tenant’s use; (d) insurance deductibles, and co-insurance payments; (e) costs incurred in connection with the presence of any
Hazardous Material, except to the extent caused by the release or emission of the Hazardous Material in question by Tenant; (f) expense reserves; (g) costs which could properly be capitalized under generally accepted accounting principles,
except such costs to the extent included in Sections 6.2(E) and 6.2(H) above; (h) costs for services not provided to Tenant under this Lease or of a nature that are payable directly by Tenant under this Lease; and (i) any fee, profit or
compensation for management and administration of the Project in excess of 4% of gross rent. Notwithstanding anything to the contrary in these Articles 5 or 6, Tenant shall not be required to pay any expenses or taxes otherwise due hereunder if
Landlord first notifies Tenant of such expenses or taxes in a statement received by Tenant more than eighteen (18) months after such expenses or taxes are incurred. 
 6.3. Less Than Full Occupancy. If the Building or the Project are less than ninety-five percent (95%) occupied during any year of the Term, including the Base Year, Operating Expenses for each
such calendar year shall be adjusted to equal Landlord’s reasonable estimate of Operating Expenses as though ninety-five percent (95%) of the total rentable area of the Building and/or the Project as applicable had been occupied.
Notwithstanding anything herein to the contrary, Tenant shall have no obligation to pay the cost of any Taxes or Operating Expenses of a type not also included in the actual Taxes or Operating Expenses of the Base Year unless the initial cost of
such Tax or Operating Expense is added to the Taxes or Operating Expenses of the Base Year. 
 6.4. Estimates of Operating
Expenses. Tenant shall pay to Landlord each month at the same time and in the same manner as monthly Base Rent one-twelfth (1/12th) of Landlord’s estimate of the amount of Operating Expenses payable by Tenant for the then-current

  
 6 

 
calendar year. If at any time it appears to Landlord that Tenant’s share of Operating Expenses payable for the current calendar year will vary from Landlord’s estimate, Landlord may
give notice to Tenant of Landlord’s revised estimate for the calendar year, and subsequent payments by Tenant for the calendar year shall be based on the revised estimate. Within one hundred twenty (120) days after the close of each
calendar year, or as soon after such 120-day period as practicable, Landlord shall deliver to Tenant a statement in reasonable detail of the actual amount of Operating Expenses payable by Tenant for such calendar year. Landlord’s failure to
provide such statement to Tenant within the 120-day period shall not act as a waiver and shall not excuse Tenant or Landlord from making the adjustments to reflect actual costs as provided herein. If on the basis of such statement Tenant owes an
amount that is less than the estimated payments for such calendar year previously made by Tenant, Landlord shall credit such excess against the next payment of Rent due. If on the basis of such statement Tenant owes an amount that is more than the
estimated payments for such calendar year previously made by Tenant, Tenant shall pay the deficiency to Landlord within thirty (30) days after delivery of the statement. In addition, if, after the end of any calendar year or any annual
adjustment of Operating Expenses for a calendar year, Operating Expenses are incurred or billed to Landlord that are attributable to any period within the Term (e.g., sewer district flow fees), Landlord shall notify Tenant of its share of such
additional Operating Expenses and Tenant shall pay such amount to Landlord within thirty (30) days after Landlord’s written request therefor. The obligations of Landlord and Tenant under this Section 6.4 with respect to the
reconciliation between the estimated and actual amounts of Operating Expenses payable by Tenant for the last year of the Term shall survive the termination of this Lease. Tenant or its authorized representative compensated on a non-contingent basis
shall have the right to inspect the books of Landlord, for the purpose of verifying the information contained in any Operating Expense statement. 
 6.5. Payment at End of Term. Any amount payable by Tenant which would not otherwise be due until after the termination of this Lease, shall, if the exact amount is uncertain at the time that this
Lease terminates, be paid by Tenant to Landlord upon such termination in an amount to be estimated by Landlord with an adjustment to be made once the exact amount is known. 
 7. Permitted Use. 
 7.1. Use and Compliance with Laws. The
Premises shall be used and occupied by Tenant solely for the Permitted Use set forth in the Basic Lease Information. Tenant shall, at Tenant’s expense, comply promptly with all applicable federal, state and local laws, regulations, ordinances,
rules, orders, and requirements in effect during the Term relating to the condition, use or occupancy of the Premises. Tenant shall not use or permit the use of the Premises in any manner that will tend to create waste or a nuisance, or that
unreasonably disturbs other tenants of the Building or Project, nor shall Tenant place or maintain any signs, antennas, awnings, lighting or plumbing fixtures, loudspeakers, exterior decoration or similar devises on the Building or the Project or
visible from the exterior of the Premises without Landlord’s prior written consent, which consent may be withheld in Landlord’s sole discretion. Tenant shall not use any corridors, sidewalks, stairs, elevators or other areas outside of the
Premises for storage or any purpose other than access to the Premises. Except as otherwise provided herein, Tenant shall not use, keep or permit to be used or kept on the Premises any foul or noxious gas or substance, nor shall Tenant do or permit
to be done anything in and about the Premises, either in connection with activities hereunder expressly permitted or otherwise, which would cause an increase in premiums for or a cancellation of any policy of insurance (including fire insurance)
maintained by Landlord in connection with the Premises, Building or Project or which would violate the terms of any covenants, conditions or restrictions, the design guidelines, the sign guidelines affecting the Building or the land on which it is
located, or the Rules (as the term is defined under Section 7.4.2 below). Notwithstanding anything in this Lease to the contrary, Tenant shall not be required to comply with or cause the Premises to comply with any laws, rules, regulations or
insurance requirements requiring the construction of alterations unless such compliance is necessitated as a result of Tenant’s particular use of the Premises. 
 7.2. Signs. Except as provided in Section 29 of the Addendum, Tenant shall not attach or install any sign to or on any part of the outside of the Premises, the Building or the Project, or in
the halls, lobbies, windows or elevator banks of the Building without Landlord’s prior written consent, which consent may be withheld in Landlord’s sole discretion. Any signage approved by Landlord shall be subject to prior approval of and
conformance with the 

  
 7 

 
requirements of the design review committee of the Project and the design review agency of the applicable city and/or county, and shall be installed at Tenant’s sole cost and expense.
Tenant, at its sole cost and expense, shall (i) maintain all permitted signage in good condition and repair, and (ii) remove such signage upon expiration or earlier termination of this Lease and restore the Building and the Project to
their condition existing immediately prior to the placement or erection of said sign or signs in such a condition that no discoloration or other evidence of the prior sign appears on the Building where the sign previously was affixed. If Tenant
fails to do so, Landlord may maintain, repair and/or remove such signage and restore the Building and or Project to its original condition without notice to Tenant and at Tenant’s expense, the cost of which shall be payable by Tenant as
additional rent. 
 7.3. Suitability. Tenant acknowledges that, except as otherwise expressly provided in this Lease,
neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the Premises, Building or with respect to the suitability or fitness of either for the conduct of Tenant’s business or for any other purpose.

 7.4. Use of Common Areas. 
 7.4.1. Right to Use Common Areas. Landlord gives Tenant and its authorized employees, agents, customers, representatives and invitees the nonexclusive right to use the Common Areas with others who
are entitled to use the Common Areas, subject to Landlord’s rights as set forth in this Section 7.4. 
 7.4.2.
Rules. All Common Areas shall be subject to the exclusive control and management of Landlord and Landlord shall have the right to establish, modify, amend and enforce reasonable rules and regulations with respect to the Common Areas. Tenant
acknowledges receipt of a copy of the current rules and regulations (the “Rules”) attached hereto as Exhibit D, and agrees that they may, from time to time, be modified or amended by Landlord in a commercially reasonable manner.
Tenant agrees to abide by and conform with the Rules; to cause its concessionaires and its and their employees and agents to abide by the Rules; and to use its best efforts to cause its customers, invitees and licensees to abide by the Rules.
Notwithstanding anything herein to the contrary, Tenant shall not be required to comply with any new rule or regulation unless the same applies non-discriminatorily to all occupants of the Project, does not unreasonably interfere with Tenant’s
use of the Premises or Tenant’s parking rights and does not materially increase the obligations or decrease the rights of Tenant under this Lease. 
 7.4.3. Use. So long as the same do not unreasonably interfere with Tenant’s access to the Premises or Tenant’s parking rights, Landlord shall have the right to close temporarily any
portion of the Common Areas for the purpose of discouraging use by parties who are not tenants or customers of tenants; to use portions of the Common Areas while engaged in making additional improvements or repairs or alterations to the Building or
the Project; to use or permit the use of the Common Areas by others in the Project to whom Landlord may grant or have granted such rights; and to do and perform such acts in, to, and with respect to, the Common Areas as in the use of good business
judgment Landlord shall determine to be appropriate for the Project. 
 7.4.4. Change in Common Areas. So long as the
same do not unreasonably interfere with Tenant’s access to the Premises or Tenant’s parking rights, Landlord shall have the right to increase or reduce the Common Areas, provided the Project meets the parking requirement under
Section 7.6 below. 
 7.4.5. Recycling. Tenant shall cooperate with Landlord and other tenants in the Project in
recycling waste paper, cardboard or such other materials identified under any trash recycling program that may be established in order to reduce trash collection costs. 
 7.5. Environmental Matters. 
 7.5.1. Hazardous Materials. The term
“Hazardous Materials” as used herein means any petroleum products, asbestos, polychlorinated biphenyls, P.C.B.’s, or chemicals, compounds, materials, mixtures or substances that are now or hereafter defined or listed in, or otherwise
classified as a “hazardous substance”, “hazardous material”, “hazardous waste”, “extremely hazardous waste”, “infectious waste”, “toxic substance”, “toxic pollutant” or

  
 8 

 
any other formulation intended to define, list or classify substances by reason of deleterious properties such as ignitability, corrosivity, reactivity, carcinogenicity or toxicity pursuant to
any federal, state or local environmental law, regulation, ordinance, resolution, order or decree relating to industrial hygiene, environmental protection or the use, analysis, generation, manufacture, storage, release, disposal or transportation of
the same (“Hazardous Materials Laws”). 
 7.5.2. Tenant’s Covenants. Except for ordinary office supplies
and janitorial cleaning materials which in common business practice are customarily and lawfully used, stored and disposed of in small quantities, Tenant shall not use, manufacture, store, release, dispose or transport any Hazardous Materials in,
on, under or about the Premises, the Building or the Project without giving prior written notice to Landlord and obtaining Landlord’s prior written consent, which consent Landlord may withhold in its reasonable discretion. Tenant shall at its
own expense procure, maintain in effect, and comply with all conditions of any and all permits, licenses, and other governmental and regulatory approvals required in connection with Tenant’s generation, use, storage, disposal and transportation
of Hazardous Materials. Except as discharged into the sanitary sewer in strict accordance and conformity with all applicable Hazardous Materials Laws, Tenant shall cause any and all Hazardous Materials removed from the Premises to be removed and
transported solely by duly licensed haulers to duly licensed facilities for final disposal of such materials and wastes. Tenant shall not maintain or install in, on, under or about the Premises, the Building or the Project any above or below ground
storage tanks, clarifiers or sumps, nor any wells for the monitoring of ground water, soils or subsoils. 
 7.5.3.
Notice. To the extent of Tenant’s actual knowledge, Tenant shall immediately notify Landlord in writing of: (a) any enforcement, cleanup, removal or other governmental or regulatory action relating to the Premises instituted,
completed or threatened pursuant to any Hazardous Materials Law; (b) any claim made or threatened by any person or entity against Tenant or the Premises relating to damage, contribution, cost, recovery, compensation, loss or injury resulting
from or claimed to result from any Hazardous Materials; and (c) any reports, information, inquiries or demands made, ordered, or received by or on behalf of Tenant which arise out of or in connection with the existence or potential existence of
any Hazardous Materials in, on, under or about the Premises, the Building or the Project, including, without limitation, any complaints, notices, warnings, asserted violations, or mandatory or voluntary informational filings with any governmental
agency in connection therewith, and immediately supply Landlord with copies thereof. 
 7.5.4. Indemnity. Tenant shall
indemnify, defend (by counsel reasonably acceptable to Landlord), protect and hold harmless Landlord, and each of Landlord’s officers, directors, partners, employees, affiliates, joint venturers, members, trustees, owners, shareholders,
principals, agents, representatives, lenders, successors and assigns, from and against any and all claims, liabilities, damages, fines, penalties, forfeitures, losses, cleanup and remediation costs or expenses (including attorneys’ fees) or
death of or injury to any person or damage to any property whatsoever, arising from or caused in whole or in part, directly or indirectly, by (i) the use, analysis, generation, manufacture, storage, release, disposal, or transportation of
Hazardous Materials by Tenant and Tenant’s agents, employees, contractors, licensees or invitees to, in, on, under, about or from the Premises, the Building or the Project, or (ii) Tenant’s failure to comply with any Hazardous
Materials Law. Tenant’s obligations hereunder shall include, without limitation, and whether foreseeable or unforeseeable, all costs of any required or necessary repair, cleanup, detoxification or decontamination of the Premises, the Building,
or the Project and the preparation and implementation of any closure, remedial action or other required plans in connection therewith, and shall survive the expiration or earlier termination of this Lease. 

7.5.5. Landlord’s Rights. Subject to the terms of Section 22.5 herein, Landlord shall have the right to enter the
Premises at all times upon reasonable prior notice for the purposes of ascertaining compliance by Tenant with all applicable Hazardous Materials Laws; provided, however, that in the instance of an emergency no notice shall be required. Subject to
the notice requirements in Section 15.1, Landlord shall have the option to declare a default of this Lease for the release or discharge of Hazardous Materials by Tenant or Tenant’s employees, agents, contractors, or invitees on the
Premises, Building or Project in violation of law or in deviation from prescribed procedures in Tenant’s use or storage of Hazardous Materials. If Tenant fails to comply with any of the provisions under this Section 7.5, Landlord shall
have the right (but not the obligation) to remove or otherwise cleanup any Hazardous 

  
 9 

 
Materials from the Premises, the Building or the Project. In such case, the costs of any Hazardous Materials investigation, removal or other cleanup (including, without limitation,
transportation, storage, disposal and attorneys’ fees and costs) will be additional rent due under this Lease, whether or not a court has ordered the cleanup, and will become due and payable on demand by Landlord. 

7.6. Parking. Landlord grants to Tenant and Tenant’s customers, suppliers, employees and invitees during the Term, including
any extension thereof, the right to use in the parking areas designated on Exhibit A-2 the number of parking spaces stated in the Basic Lease Information on an unreserved basis for the use of motor vehicles, subject to rights reserved to
Landlord as specified in this Section 7.6. In addition, Tenant may use the parking stalls located in the vicinity of the building pad located adjacent to the Club One building at 1201 Redwood Way until such time as a building is constructed on
such pad. Subject to the terms of Section 7.4, Landlord reserves the right to grant similar nonexclusive rights to other tenants; to promulgate rules and regulations relating to the use of the including parking area; to make changes in the
parking layout from time to time; and to do and perform any other acts in and to these areas and improvements as Landlord determines to be advisable. Tenant agrees not to overburden the parking facilities and to abide by and conform with the rules
and regulations and to cause its employees and agents to abide by and conform to the rules and regulations. Upon request, Tenant shall provide Landlord with license plate numbers of all vehicles driven by its employees and to cause Tenant’s
employees to park only in spaces specifically designated for tenant parking. Subject to the terms of Section 7.4, Landlord shall have the unqualified right to rearrange or reduce the number of parking spaces; provided, however, the ratio of the
number of parking spaces available to Tenant will be no less than 3.8 spaces per 1,000 usable square feet of the Premises. Landlord shall ensure that the parking available to the Project shall at all times comply with applicable City requirements.

 8. Services. 
 8.1. Utilities and Services. Landlord shall (i) furnish the Premises with electricity for lighting fixtures and office machines, gas, sewer, water and heat and air conditioning required for
the comfortable occupancy and operation of the Premises, during all hours of Tenant’s operation and at such other times as Tenant may reasonably request and (ii) provide customary trash pick up, and daily janitorial service on normal
business days. Landlord shall, at Landlord’s sole cost and expense, install separate metering for electricity and gas usage by Tenant in the Premises (or control systems to measure same), including without limitation electrical and/or gas for
mechanical systems such as HVAC and boilers. In such case, Tenant shall pay for such utilities (i) directly to the utility provider, in which case Tenant shall receive a credit toward its Base Rent for the budgeted cost of such utilities in the
Base Year (the “Base Year Budget Amount”, which is fourteen cents ($.14) per square foot per month for electricity and two cents ($.02) per square foot per month for gas) determined in Landlord’s reasonable discretion, or (ii) to
Landlord as additional rent, in which case Tenant shall reimburse Landlord within thirty (30) days after Landlord’s written request for the actual utility cost for such utilities in excess of the Base Year Budget Amount determined in
Landlord’s reasonable discretion. For purposes of this Lease, usual business hours are Monday through Friday, 7 am to 6 pm, national holidays excepted. Landlord shall provide Tenant with access to the Premises twenty-four hours a day, seven
days a week. For the avoidance of doubt, Tenant shall be free to use electricity, gas and HVAC in the Premises at any time without payment of any after-hours or other charge other than the separately metered utility costs; provided that
Tenant shall reimburse Landlord within thirty days following written demand for the increase in maintenance and replacement costs caused by Tenant’s usage in excess of typical office occupants determined in Landlord’s reasonable
discretion. 
 8.2. No Liability. Landlord shall not be in default hereunder or be liable for any damages or personal
injuries to any person directly or indirectly resulting from, nor shall there be any Rent abatement by reason of, any interruption or curtailment whatsoever in utility services due to causes beyond Landlord’s reasonable control; provided, in
the event of any material interruption in essential utility services in excess of two (2) continuous business days that prevents the normal operation of Tenant’s business in the Premises, which is solely caused by the negligence or willful
misconduct of Landlord, commencing on the third (3rd) continuous business day of such interruption until such essential utility services are restored, Rent shall abate to the extent Tenant’s use of the Premises are diminished.
Notwithstanding anything herein to the contrary, if the Premises should become not reasonably suitable for Tenant’s use as a 

  
 10 

 
consequence of cessation of utilities or other services, interference with access to the Premises, legal restrictions or the presence of any Hazardous Material which does not result from
Tenant’s release or emission of such Hazardous Material, and in any of the foregoing cases the interference with Tenant’s use of the Premises persists for seven (7) days, then Tenant shall be entitled to an equitable abatement of
rent to the extent of the interference with Tenant’s use of the Premises occasioned thereby. 
 9. Maintenance and
Repairs. 
 9.1. Tenant’s Repairs and Maintenance. Tenant shall, at Tenant’s expense, maintain the
Premises in good order, condition and repair, including without limitation, (i) all interior surfaces, ceilings, walls, door frames, interior window frames, floors, carpets, draperies, window coverings and fixtures, (ii) all interior
windows, doors, locks and closing devices, entrances, interior plate glass, and signs, (iii) all phone lines, electrical wiring, and equipment, switches, outlets and light bulbs, (iv) all of Tenant’s personal property, improvements
and alterations, and (vii) all other fixtures and special items installed by or for the benefit of, or at the expense of Tenant. Tenant shall not enter onto the roof area of the Building, except for the purpose of installing or maintaining
(i) Tenant’s signage to the extent Tenant is required to do so under the terms of this Lease and (ii) any of Tenant’s equipment thereon that Landlord has approved, which approval Landlord shall not unreasonably withhold,
condition, or delay. Tenant shall repair any damage to the roof area caused by its entry. 
 9.2. Landlord’s Repairs and
Maintenance. Landlord shall keep in good condition and repair the foundation, roof structure, exterior walls and other structural parts of the Building, the Building systems, the Common Areas, and all other portions of the Building not the
obligation of Tenant. Tenant expressly waives the benefits of any statute, including Civil Code Sections 1941 and 1942, which would afford Tenant the right to make repairs at Landlord’s expense or to terminate this Lease due to Landlord’s
failure to keep the Building in good order, condition and repair. Landlord shall have no liability to Tenant for any damage, inconvenience or interference with the use of the Premises by Tenant as the result of Landlord performing any such
maintenance and repair work. 
 9.3. Failure to Repair or Maintain. In the event Tenant fails to perform Tenant’s
obligations under this Section 9 within applicable notice and cure periods, Landlord may, but shall not be required to, give Tenant notice to do such acts as are reasonably required to so maintain the Premises. If Tenant shall fail to commence
such work and diligently prosecute it to completion, then Landlord shall have the right (but not the obligation) to do such acts and expend such funds at the expense of Tenant as are reasonably required to perform such work. Any amounts so expended
by Landlord will be additional rent due under this Lease, and such amounts will become due and payable on demand by Landlord. Landlord shall have no liability to Tenant for any such damages, inconvenience or interference with the use of the Premises
by Tenant as a result of performing such work. 
 9.4. Surrender of Premises. Upon the expiration or earlier termination
of this Lease, Tenant shall surrender the Premises to Landlord in the condition and repair existing as of the Commencement Date, ordinary wear and tear, casualties, condemnation, Hazardous Materials (other than those released or emitted by Tenant),
alterations or other interior improvements which it is permitted to surrender at the termination of this Lease and repairs that Tenant is not responsible for under this Lease, excepted. The term “ordinary wear and tear” as used herein
shall mean wear and tear which normally manifests itself solely through the passage of time consistent with the employment of commercially prudent measures to protect finishes and components from damage and excessive wear, the application of regular
and appropriate preventative maintenance practices and procedures, routine cleaning and servicing as often as appropriate for Class A corporate and professional office occupancies in the Petaluma office market. The term “ordinary wear and
tear” would thus encompass the natural fading of painted surfaces, fabric and materials over time, and carpet wear caused by normal foot traffic. The term “ordinary wear and tear” shall not include any damage or deterioration that
could have been prevented by Tenant’s employment of ordinary prudence, care and diligence in the occupancy and use of the Premises and the performance of all of its obligations under this Lease. Items not considered reasonable wear and tear
hereunder include the following for which Tenant shall bear the obligation for repair and restoration (except to the extent caused by the negligence or willful misconduct of Landlord or its employees or agents, or Landlord’s violation of this
Lease) (i) excessively soiled, stained, or marked surfaces or finishes; (ii) damage, including holes in 

  
 11 

 
building surfaces (e.g., cabinets, doors, walls, ceilings and floors) caused by the installation or removal of Tenant’s trade fixtures, furnishings, decorations, equipment, alterations,
utility installations, security systems, communications systems (including cabling, wiring and conduits), displays and signs; and (iii) damage to any component, fixture, hardware, system or component part thereof within the Premises, and any
such damage to the Building or Project, caused by Tenant or its agents, contractors or employees, subject to Section 11.3 herein. Tenant, at its sole cost and expense, agrees to repair any damages to the Premises caused by or in connection with
the removal of any articles of personal property, business or trade fixtures, signs, machinery, equipment, cabinetwork, furniture, moveable partitions or permanent improvements or additions, including without limitation thereto, repairing the floor
and patching and painting the walls where required by Landlord to Landlord’s reasonable satisfaction. Tenant shall indemnify Landlord against any loss or liability resulting from delay by Tenant in so surrendering the Premises, including
without limitation, any claims made by any succeeding tenant resulting from such delay. 
 10. Alterations.

 10.1. Consent Required. Tenant shall not make any alterations, improvements or additions (each, an
“Alteration”) in, on or about the Premises without Landlord’s prior written consent, which consent may be withheld by Landlord in its sole and absolute discretion. Notwithstanding the foregoing, Tenant may make Alterations without
Landlord’s prior written consent where (i) the reasonably estimated cost of the Alteration does not exceed $25,000, and (ii) such Alterations do not affect or involve the structural integrity, roof membrane, exterior areas, building
systems or water-tight nature of the Premises; provided, however, minor changes such as adding or relocating electric outlets or light switches shall not be considered to affect or involve the build systems). In requesting Landlord’s consent,
Tenant shall, at Tenant’s sole cost, submit to Landlord complete drawings and specifications describing the Alteration and the identity of the proposed contractor. Notwithstanding anything in this Lease to the contrary, Tenant’s trade
fixtures, furniture, equipment and other personal property installed in the Premises (“Tenant’s Property”) shall at all times be and remain Tenant’s property. At any time Tenant may remove Tenant’s Property from the
Premises, provided that Tenant repairs all damage caused by such removal. Landlord shall have no lien or other interest in any item of Tenant’s Property. Landlord shall have no right to require Tenant to remove any alterations unless it
notifies Tenant at the time it consents to such alteration that it shall require such alteration to be removed. 
 10.2.
Conditions. 
 10.2.1. Notice. Before commencing any work relating to Alterations requiring consent pursuant to
Section 10.1 above, Tenant shall notify Landlord of the expected date of commencement thereof and of the anticipated cost thereof. Landlord shall then have the right at any time and from time to time to post and maintain on the Premises such
notices as Landlord reasonably deems necessary to protect the Premises and Landlord from mechanics’ liens or any other liens. 
 10.2.2. Liens. Tenant shall pay when due all claims for labor or materials furnished to Tenant for use in the Premises. Tenant shall not permit any mechanics’ liens or any other liens to be
levied against the Premises for any labor or materials furnished to Tenant in connection with work performed on the Premises by or at the direction of Tenant. Tenant shall indemnify, hold harmless and defend Landlord (by counsel reasonably
satisfactory to Landlord) from any liens and encumbrances arising out of any work performed or materials furnished by or at the direction of Tenant. In the event that Tenant shall not, within five (5) business days following the imposition of
any such lien, cause such lien to be released of record by payment or posting of a proper bond, Landlord shall have, in addition to all other remedies provided herein by law, the right, but not the obligation, to cause the same to be released by
such means as it shall deem proper, including payment of the claim giving rise to such lien. All such sums paid by Landlord and all expenses incurred by it in connection therewith, including attorneys’ fees and costs, shall be payable to
Landlord by Tenant on demand with interest at the Interest Rate. 
 10.2.3. Compliance with Laws. All Alterations in or
about the Premises performed by or on behalf of Tenant shall be done in a first-class, workmanlike manner, shall not unreasonably lessen the value of leasehold improvements in the Premises, and shall be completed in compliance with all applicable
laws, ordinances, regulations and orders of any governmental authority having jurisdiction thereover, as well as the requirements of insurers of the Premises and the Building. 

  
 12 

 10.2.4. Labor Disputes. Upon Landlord’s request, Tenant shall remove any
contractor, subcontractor or material supplier from the Premises and the Building if the work or presence of such person or entity results in labor disputes in or about the Building or Project or damage to the Premises, Building or Project.

 10.2.5. Americans with Disabilities Act. Except in connection with the Tenant Improvements and Tenant Extra
Improvements constructed pursuant to the Work Letter Agreement, Landlord, at Landlord’s sole discretion, may refuse to grant Tenant permission for Alterations that require, because of application of Americans with Disabilities Act or other
laws, substantial improvements or alterations to be made to the Common Areas, provided Landlord constructed the Building and Tenant Improvements in accordance with all laws, unless Tenant pays for such improvements or alterations. 

10.2.6. End of Term. Landlord, by written notice at the time its consents to such Alteration, may require that Tenant, at
Tenant’s expense, remove any Alterations prior to or upon the expiration of this Lease, and restore the Premises to their condition prior to such Alterations. Unless Landlord requires their removal, as provided above, all Alterations made to
the Premises shall become the property of Landlord and remain upon and be surrendered with the Premises upon the expiration of this Lease; provided, however, that Tenant’s machinery, equipment (including without limitation, all of Tenant’s
rack mounted electronic equipment), and trade fixtures, other than any which may be affixed to the Premises so that they cannot be removed without material damage to the Premises, shall remain the property of Tenant and may be removed by Tenant
subject to the provisions of Section 9.4 above. 
 10.3 Antenna. Tenant shall have the right for the duration of the
Term to install, maintain and operate solely for its use (and not for use by any third party) a satellite dish antenna or wireless access antenna, mounted on a non-penetrating structure, and related plenum-rated cabling (collectively, the
“Antenna”) on the roof of the Building in a location selected by Landlord. Tenant shall (a) install and maintain the Antenna at Tenant’s sole cost and expense, (b) obtain and maintain all required governmental permits for
the Antenna, (c) comply with all applicable codes and permits concerning the installation, maintenance and operation of the Antenna, and (d) place the Antenna behind visual screening as required by Landlord. If the installation and/or
maintenance of the Antenna requires any penetration of the roof of the Building, Landlord may elect for Landlord’s contractor to perform the installation or maintenance thereof at Tenant’s sole cost and expense. Tenant shall not make any
physical changes to the Antenna without Landlord’s prior written approval in each instance. Prior to the expiration or earlier termination of the Lease, Tenant shall remove the Antenna and repair all damage to the Building (including without
limitation, the roof and conduits thereof) as a result of the installation, operation, maintenance, use or removal of the Antenna, and restore that Building to its condition as of the date of installation of the Antenna. Tenant shall not allow any
provider of telecommunication, video, data or related services to locate any equipment on the roof of the Building to the extent the equipment is for use by persons or entities other than Tenant. 

11. Insurance and Indemnity. 
 11.1. Insurance. Tenant shall obtain and maintain during the Term the following insurance: 
 11.1.1. Commercial General Liability Insurance. Commercial general liability insurance (occurrence form) having a combined single limit of not less than $2,000,000 per occurrence, providing
coverage for, among other things, blanket contractual liability, premises, product/completed operations and personal injury coverage (in a form, with a deductible amount, and with carriers reasonably acceptable to Landlord). 

11.1.2. Automobile Liability Insurance. Comprehensive automobile liability insurance having a combined single limit of not less
than Two Million Dollars ($2,000,000) per occurrence, and insuring Tenant against liability for claims arising out of ownership, maintenance or use of any owned, hired, borrowed or non-owned automobiles; 

  
 13 

 11.1.3. Workers’ Compensation and Employer’s Liability Insurance.
Workers’ compensation insurance having limits not less than those required by state statute and federal statute, if applicable, and covering all persons employed by Tenant in the conduct of its operations on the Premises (including the all
states endorsement), together with employer’s liability insurance coverage in the amount of at least Two Million Dollars ($2,000,000); 
 11.1.4. Property Insurance. “Special Form” property insurance (or its equivalent if “Special Form” property insurance is not available), including vandalism and malicious
mischief, and endorsement for earthquake sprinkler damage, each covering damage to or loss of Tenant’s personal property, fixtures and equipment, including electronic data processing equipment (“EDP Equipment”), media and extra
expense, and all alterations, additions and improvements made by Tenant to the Premises other than the Tenant Improvements and Tenant Extra Improvements (and coverage for the full replacement cost thereof). EDP Equipment, media and extra expense
shall be covered for perils insured against in the so-called “EDP Form”. If the property of Tenant’s invitees is to be kept in the Premises, warehouser’s legal liability or bailee customers insurance for the full replacement cost
of such property; 
 11.1.5. Business Income/Extra Expense Insurance. Business income with extra expense insurance (form
CP 0030 or equivalent) in an amount not less than the annual Base Rent and Additional Rent payable by Tenant hereunder for the then current calendar year, with a minimum fifty percent (50%) coinsurance percentage, the agreed value option and
building ordinance (Form CP 1531 or equivalent). Any boiler and machinery policies or endorsements obtained shall also include these same provisions and coverages; and 
 11.1.6. Additional Insurance. Any such other insurance as Landlord or Landlord’s lender may reasonably require consistent with insurance coverages typically required by commercial landlords of
similar property in the vicinity of Petaluma, California. Notwithstanding the foregoing, Tenant shall not be required to obtain such additional insurance during the Term or Extended Term, to the extent the result of obtaining such additional
insurance would result in Tenant paying in excess of an amount equal to one hundred and three percent (103%) of the total insurance premiums paid by Tenant for the immediately preceding calendar year. 

11.2. General. The insurance carrier shall be authorized to do business in the State of California, with a policyholders and
financial rating of at least A-:VII Class status as rated in the most recent edition of Best’s Key-Rating guide. Tenant’s commercial general liability insurance policy shall be endorsed to provide that (i) Landlord is designated as an
additional insured, and (ii) such insurance is primary with respect to Landlord and that any other insurance maintained by Landlord is excess and noncontributing with such insurance. Tenant shall notify Landlord not less than thirty
(30) days prior to any cancelation or reduction in such insurance coverage. If, in the opinion of Landlord’s lender or in the commercially reasonable opinion of Landlord’s insurance adviser, the specified amounts of coverage are no
longer adequate, such coverage shall, within thirty (30) days’ written notice to Tenant, be appropriately increased to coverages consistent with those typically required by commercial landlords of similar property in the vicinity of
Petaluma, California. Notwithstanding the foregoing, Tenant shall not be required to obtain such increased coverages during the Term or Extended Term, to the extent the result of obtaining such increased coverages would result in Tenant paying in
excess of an amount equal to one hundred and three percent (103%) of the total insurance premiums paid by Tenant for the immediately preceding calendar year. Prior to the commencement of the Term, Tenant shall deliver to Landlord a duplicate of
such policy or a certificate thereof to Landlord for retention by it with endorsements. At least five (5) days prior to the expiration of such policy or any renewal or modification thereof, Tenant shall deliver to Landlord a replacement or
renewal binder, followed by a duplicate policy or certificate within a reasonable time thereafter. If Tenant fails to obtain such insurance or to furnish Landlord any such duplicate policy or certificate as herein required, Landlord may, at its
election, without notice to Tenant and without any obligation to do so, procure and maintain such coverage and Tenant shall reimburse Landlord on demand as additional rent for any premium so paid by Landlord. 

11.3. Waiver of Claims. Notwithstanding anything in this Lease to the contrary, Landlord waives all claims against Tenant and
Tenant’s officers, directors, partners, employees, agents and representatives for loss or damage to any property to the extent that such loss or 

  
 14 

 
damage is due to a risk which is actually insured against or which is required to be insured against under this Lease by property insurance, without regard to the negligence or willful misconduct
of the entity so released. Tenant waives all claims against Landlord and Landlord’s officers, directors, partners, employees, affiliates, joint venturers, members, trustees, owners, shareholders, principals, agents, representatives, successors
and assigns, for loss or damage to any property to the extent that such loss or damage is due to a risk which is actually insured against or which is required to be insured against under this Lease by property insurance, without regard to the
negligence or willful misconduct of the entity so released. The insuring party shall, upon obtaining the policies of insurance required under this Lease, give notice to the insurance carrier or carriers that the foregoing mutual waiver of
subrogation is contained in this Lease. Tenant agrees that in the event of a sale, assignment or transfer of the Premises by Landlord, this waiver of subrogation shall continue in favor of the original Landlord and any subsequent Landlord. All of
Landlord’s and Tenant’s repair and indemnity obligations under this Lease shall be subject to the waiver contained in this paragraph. 
 11.4. Landlord’s Insurance. During the Term, Landlord shall keep the Building, including all Tenant Improvements and Tenant Extra Improvements, insured against loss or damage by fire, with
extended coverage and vandalism, malicious mischief and special extended perils (all risk) endorsements or their equivalents, in amounts not less than one hundred percent (100%) of the replacement cost of the Building and structures insured.
Landlord may maintain rent insurance, for the benefit of Landlord, equal to at least one year’s Base Rent hereunder. If this Lease is terminated as a result of damage by fire, casualty or earthquake, all insurance proceeds from policies carried
by Landlord shall be paid to and retained by Landlord, subject to the rights of any authorized encumbrancer of Landlord. 

11.5. Earthquake and Flood. Tenant acknowledges that Landlord does not, at the time of the signing of this Lease, insure the
Building for earthquake or flood damage. Landlord may, when Landlord deems the premiums to be reasonable, insure the Building fully or partially for earthquake and/or flood damage. At such time, the premium for earthquake and/or flood insurance will
be added to the Operating Expenses for such year and the Base Year for purposes of determining additional rent. 
 11.6.
Indemnity. Tenant waives all claims against Landlord for any injury to Tenant’s business or loss of income there from, damage to any property or injury to or death of any person in, on, or about the Premises, the Building, or any other
portion of the Project arising at any time and from any cause, unless caused by the negligence or willful misconduct of Landlord or its agents, employees or contractors or Landlord’s violation of this Lease. Tenant shall indemnify, defend (by
counsel reasonably satisfactory to Landlord) and hold harmless Landlord, and Landlord’s officers, directors, partners, employees, affiliates, joint venturers, members, trustees, owners, shareholders, principals, agents, representatives,
successors and assigns, from and against all claims, costs, damages, actions, indebtedness and liabilities (except such as may arise from the negligence, willful misconduct of Landlord, and Landlord’s officers, directors, partners, employees,
affiliates, joint venturers, members, trustees, owners, shareholders, principals, agents, representatives, successors and assigns, or Landlord’s violation of this Lease) arising by reason of any death, bodily injury, personal injury, property
damage or any other injury or damage in connection with Tenant’s negligence, willful misconduct, or violation of this Lease. The foregoing indemnity obligation of Tenant shall include reasonable attorneys’ fees, and all other reasonable
costs and expenses incurred by Landlord from the first notice that any claim or demand is to be made. The provisions of this Section 11.6 shall survive the termination or expiration of this Lease with respect to any damage, injury, or death
occurring prior to such expiration or termination. Landlord shall indemnify, defend, protect and hold harmless Tenant from, all losses, damages, liabilities, claims, attorneys’ fees, costs and expenses arising from the negligence or willful
misconduct of Landlord or its agents, contractors, licensees or invitees or a violation of Landlord’s obligations or representations under this Lease. 
 12. Damage or Destruction. 
 12.1. Landlord’s Obligation to
Rebuild. Subject to the provisions of Sections 12.2, 12.3 and 12.4 below, if, during the Term, the Premises or portions of the Building required for Tenant’s use of the Premises are totally or partially destroyed from any casualty, Landlord
shall, within ninety (90) days after the destruction, commence to restore the same to substantially the same condition as they were in immediately before the destruction and prosecute the same diligently to completion. Such destruction shall
not terminate this Lease. Landlord’s obligation 

  
 15 

 
shall not include repair or replacement of Tenant’s alterations (other than the Tenant Improvements and Tenant Extra Improvements) or Tenant’s equipment, furnishings, fixtures and
personal property. If the existing laws do not permit the Premises to be restored to substantially the same condition as they were in immediately before destruction, and Landlord is unable to get a variance to such laws to permit the commencement of
restoration of the Premises within the 90-day period, then either party may terminate this Lease by giving written notice to the other party within thirty (30) days after expiration of the 90-day period. 

12.2. Right to Terminate. Landlord shall have the option to terminate this Lease if the Premises or portions of the Building
required for Tenant’s use of the Premises are destroyed or damaged by fire or other casualty, regardless of whether the casualty is insured against under this Lease, if Landlord reasonably determines that (i) there are insufficient
insurance proceeds made available to Landlord to pay all of the costs of the repair or restoration for reasons other than Landlord’s failure to carry the required insurance (provided proceeds in the amount of deductibles and co-insurance
amounts shall be considered to have been made available to Landlord), or (ii) the repair or restoration of the Premises or such portions of the Building cannot be completed within two hundred seventy (270) days after the date of the
casualty. If Landlord elects to exercise the right to terminate this Lease as a result of a casualty, Landlord shall exercise the right by giving Tenant written notice of its election to terminate this Lease within forty-five (45) days after
the date of the casualty, in which event this Lease shall terminate fifteen (15) days after the date of the notice. If Landlord does not exercise its right to terminate this Lease, Landlord shall promptly commence the process of obtaining all
of the necessary permits and approvals for the repair or restoration of the Premises or the Building as soon as practicable and thereafter prosecute the repair or restoration of the Premises or the Building diligently to completion and this Lease
shall continue in full force and effect. Notwithstanding the foregoing, if the Premises are damaged by any peril and Landlord does not terminate this Lease, then Tenant shall have the option to terminate this Lease if the Premises cannot be, or are
not in fact, fully restored by Landlord to their prior condition within two hundred seventy (270) days after the damage. During any rebuilding following a casualty that displaces Tenant from the Premises, Landlord shall use reasonable efforts
to assist Tenant in procuring temporary space at market rates in any other nearby buildings owned by Landlord or affiliates of Landlord. 
 12.3. Last Year of Term. In addition to Landlord’s right to terminate this Lease under Section 12.2, Landlord shall have the right to terminate this Lease upon thirty (30) days’
prior written notice to Tenant if the Premises or Building is substantially destroyed or damaged during the last six (6) months of the Term. Landlord shall notify Tenant in writing of its election to terminate this Lease under this
Section 12.3, if at all, within forty-five (45) days after Landlord determines that the Premises or Building has been substantially destroyed. If Landlord does not elect to terminate this Lease, the repair of the Premises or Building shall
be governed by Sections 12.1, 12.2 and 12.4. 
 12.4. Uninsured Casualty. If the Premises are damaged from any casualty,
the risk of which is not covered by the property insurance Landlord is required to carry hereunder, Landlord may within ninety (90) days following the date of such damage: (i) commence to restore the Premises to substantially the same
condition as they were in immediately before the destruction and prosecute the same diligently to completion, in which event this Lease shall continue in full force and effect; or (ii) within the 90-day period Landlord may elect not to so
restore the Premises, in which event this Lease shall cease and terminate. In either such event, Landlord shall give Tenant written notice of its intention within the 90-day period. Notwithstanding anything in this Lease to the contrary, Landlord
shall not have the right to terminate this Lease if Tenant agrees to pay for the uninsured cost to repair the Premises in excess thereof. Notwithstanding the foregoing, including Section 12.2 above, Landlord shall not have the right to
terminate this Lease if it actually intends to restore the casualty damage. 
 12.5. Abatement of Rent. In the event of
destruction or damage to the Premises, if this Lease is not terminated as above provided, there shall be an abatement or reduction of Rent between the date of destruction and the date Landlord substantially completes its reconstruction obligations,
based upon the extent to which the destruction materially interferes with Tenant’s use of the Premises. All other obligations of Tenant under this Lease shall remain in full force and effect. Except for abatement of Rent, Tenant shall have no
claim against Landlord for any loss suffered by Tenant due to damage or destruction of the Premises or any work of repair undertaken as herein provided. 

  
 16 

 12.6. Waiver. The provisions of California Civil Code Sections 1932(2) and 1933(4),
and any successor statutes, are inapplicable with respect to any destruction of the Premises, such sections providing that a lease terminates upon the destruction of the Premises unless otherwise agreed between the parties to the contrary.

 13. Eminent Domain. 
 13.1. Condemnation. If all or any part of the Premises shall be taken as a result of the exercise of the power of eminent domain or sold in lieu of condemnation (“Condemned”), this Lease
shall terminate as to the part so taken as of the date of title vesting in such proceeding. In the case of a partial condemnation of greater than fifty percent (50%) of the rentable area of the Premises, either Landlord or Tenant shall have the
right to terminate this Lease as to the balance of the Premises by notice to the other within thirty (30) days after the date of title vesting in such proceeding. In the event of a partial condemnation of the Premises which does not result in a
termination of this Lease, the monthly Rent thereafter to be paid shall be equitably reduced on a rentable square footage basis. If the continued occupancy of Tenant is materially interfered with for any time during the partial taking,
notwithstanding the partial taking does not terminate this Lease as to the part not so taken, the Rent shall proportionately abate so long as Tenant is not able to continuously occupy the part remaining and not so taken. 

13.2. Award. If the Premises are wholly or partially Condemned, Landlord shall be entitled to the entire award paid in connection
with such condemnation, and Tenant waives any right or claim to any part thereof from Landlord or the condemning authority. Tenant shall have the right to claim and recover from the condemning authority, but not from Landlord, such compensation as
may be separately awarded or recoverable by Tenant in Tenant’s own right on account of any and all costs which Tenant might incur in moving Tenant’s merchandise, furniture, fixtures, leasehold improvements and equipment to a new location,
relocation costs, lost goodwill, the unamortized value of any improvements made at Tenant’s expense and the “bonus value” of this Lease. 
 14. Assignment and Subletting. 
 14.1. Assignment and Subletting;
Prohibition. Tenant shall not assign, mortgage, pledge or otherwise transfer this Lease, in whole or in part (each hereinafter referred to as an “assignment”), nor sublet or permit occupancy by any party other than Tenant of all or any
part of the Premises (each hereinafter referred to as a “sublet” or “subletting”), without the prior written consent of Landlord in each instance, which consent shall not be unreasonably withheld. No assignment or subletting by
Tenant shall relieve Tenant of any obligation under this Lease, including Tenant’s obligation to pay Base Rent and additional rent hereunder. Any purported assignment or subletting contrary to the provisions of this Lease without
Landlord’s prior written consent shall be void. The consent by Landlord to any assignment or subletting shall not constitute a waiver of the necessity for obtaining Landlord’s consent to any subsequent assignment or subletting. Landlord
may consent to any subsequent assignment or subletting, or any amendment to or modification of this Lease with the assignees of Tenant, without notifying Tenant or any successor of Tenant, and without obtaining its or their consent thereto, and such
action shall not relieve Tenant or any successor of Tenant of any liability under this Lease. As additional rent hereunder, Tenant shall reimburse Landlord for all reasonable legal fees and other expenses incurred by Landlord in connection with any
request by Tenant for consent to an assignment or subletting, not to exceed $1,500 in each instance. 
 14.2. Information to
be Furnished. If Tenant desires at any time to assign its interest in this Lease or sublet the Premises, Tenant shall first notify Landlord of its desire to do so and shall submit in writing to Landlord: (i) the name of the proposed
assignee or subtenant; (ii) the nature of the proposed assignee’s or subtenant’s business to be conducted in the Premises; (iii) the terms and provisions of the proposed assignment or sublease, including the date upon which the
assignment shall be effective or the commencement date of the sublease (hereinafter referred to as the “Transfer Effective Date”) and a copy of the proposed form of assignment or sublease; and (iv) such financial information,
including financial statements, and other information as Landlord may reasonably request concerning the proposed assignee or subtenant. 
 14.3. Landlord’s Election. At any time within thirty (30) days after Landlord’s receipt of the information specified in Section 14.2, Landlord may, by written notice to Tenant,
elect to (i) consent to the proposed assignment or subletting by Tenant; or (ii) withhold its consent to the proposed assignment or subletting by Tenant. 

  
 17 

 14.4. Intentionally Deleted. 

14.5. Withholding Consent. Without limiting other situations in which it may be reasonable for Landlord to withhold its consent to
any proposed assignment or sublease, Landlord and Tenant agree that it shall be reasonable for Landlord to withhold its consent in any one (1) or more of the following situations: (1) in Landlord’s reasonable judgment, the proposed
subtenant or assignee or the proposed use of the Premises would generate vehicle or foot traffic, parking or occupancy density materially in excess of the amount customary for the Building or the Project or result in a materially greater use of the
elevator, janitorial, security or other Building services (e.g., HVAC, trash disposal and sanitary sewer flows) than is customary for the Project; or (2) the proposed assignee or subtenant is a governmental entity, agency or department or the
United States Post Office. If Landlord fails to elect any of the alternatives within the thirty (30) day period referenced in Section 14.3, it shall be deemed that Landlord has granted its consent to the proposed assignment or sublease.

 14.6. Bonus Rental. If, in connection with any assignment or sublease, Tenant receives rent or other consideration,
either initially or over the term of the assignment or sublease, in excess of the Rent called for hereunder, or in case of the sublease of a portion of the Premises, in excess of such Rent fairly allocable to such portion, Tenant shall, after first
deducting the reasonable expenses incurred by Tenant for (i) any alterations or improvements to the Premises in connection with the assignment or sublet, and (ii) any brokerage commissions in connection with the assignment or sublet, as
additional rent hereunder, fifty percent (50%) of the excess of each such payment of Rent or other consideration received by Tenant promptly after Tenant’s receipt of such Rent or other consideration. To the extent that a subtenant or
assignee purchases goods or services from sublandlord or an affiliate of sublandlord for an amount in excess of the fair market value for such goods or services, such costs incurred or amounts expended shall be deemed to be “other
consideration” for purposes of calculating excess Rent due to Landlord hereunder. 
 14.7. Scope. If the Premises or
any part thereof is sublet or occupied by anybody other than Tenant, Landlord may collect rent from the assignee, subtenant or occupant and apply the net amount collected to the Rent due herein and apportion any excess rent so collected in
accordance with the terms of Section 14.6, but no such assignment, subletting, occupancy or collection shall be deemed a waiver of the provisions regarding assignment and subletting, or the acceptance of the assignee, subtenant or occupant as
tenant, or a release of Tenant from the further performance by Tenant of covenants on the part of Tenant herein contained. No assignment or subletting shall affect the continuing primary liability of Tenant (which, following assignment, shall be
joint and several with the assignee), and Tenant shall not be released from performing any of the terms, covenants and conditions of this Lease. 
 14.8. Executed Counterparts. No sublease or assignment shall be valid, nor shall any subtenant or assignee take possession of the Premises, until a fully executed counterpart of the sublease or
assignment has been delivered to Landlord and Landlord, Tenant and the applicable assignee or subtenant have entered into a consent to assignment or sublease in a form acceptable to Landlord. 

14.9. Intentionally Deleted. 

  
 18 

 14.10. Affiliated Transfers. Notwithstanding anything herein to the contrary, a sale,
issuance, or transfer of Tenant’s capital stock shall not be deemed an assignment or subletting of this Lease or the Premises, and the assignment or subletting by Tenant of all or any portion of this Lease or the Premises to (i) a parent
or subsidiary of Tenant or to an entity under common control with Tenant, or (ii) any entity which purchases a substantial portion of the assets of Tenant, or (iii) any entity related to Tenant by merger, consolidation or reorganization
(all such persons or entities described in clauses (i), (ii) and (iii) being sometimes herein referred to as “Affiliates”) shall not be deemed an assignment or subletting under this Section 14 (hence, the aforesaid events
shall not be subject to obtaining Landlord’s prior consent and the provisions of Section 14.6 shall not apply thereto), provided in all instances that: 
 14.10.1. any such Affiliate was not formed as a subterfuge to avoid the obligations of this Section 14; and 
 14.10.2. any such assignment or sublease shall be subject to all of the terms and provisions of this Lease, and such assignee or sublessee (i.e., any such Affiliate), other than in the case of an
Affiliate resulting from a merger or consolidation, shall assume all the obligations of Tenant under this Lease. 
 15.
Default by Tenant. 
 15.1. Events of Default. The occurrence of any of the following events shall constitute
an event of default on the part of Tenant under this Lease: 
 15.1.1. Payment. A failure by Tenant to pay Rent within
five (5) days after Landlord’s delivery of written notice that such payment is due; 
 15.1.2. Bankruptcy. The
bankruptcy or insolvency of Tenant, any transfer by Tenant to defraud creditors, any assignment by Tenant for the benefit of creditors, or the commencement of any proceedings of any kind by or against Tenant under any provision of the Federal
Bankruptcy Act or under any other insolvency, bankruptcy or reorganization act unless, in the event any such proceedings are involuntary, Tenant is discharged from the same within sixty (60) days thereafter; the appointment of a receiver for a
substantial part of the assets of Tenant in each case which is not discharged within thirty (30) days or the levy upon this Lease or any estate of Tenant hereunder by any attachment or execution; 

15.1.3. Abandonment or Vacation. The abandonment of the Premises; 

15.1.4. Performance of Lease Terms. Tenant’s failure to perform any of the terms, covenants, agreements or conditions of
this Lease to be observed or performed by Tenant (excluding any event of default under Section 15.1.1 above), which default has not been cured within thirty (30) days after written notice thereof by Landlord to Tenant; provided, however,
that if the nature of the default is such that the same cannot reasonably be cured within the 30-day period, Tenant shall not be deemed to be in default if within such period Tenant shall commence such cure and thereafter diligently prosecute the
same to completion; and 
 15.1.5. Failure to Comply. Tenant’s failure to comply with the provisions contained in
Sections 18 and 19 which failure has not been cured within ten (10) days after written notice thereof by Landlord to Tenant. 
 An event of
default shall constitute a default by Tenant under this Lease. In addition, any notice required to be given by Landlord under this Lease shall be in lieu of and not in addition to any notice required under Section 1161 of the California Civil
Code of Procedure. 
 15.2. Remedies. In the event of any default by Tenant, Landlord may at any time thereafter, without
limiting Landlord in the exercise of any right or remedy at law or in equity which Landlord may have by reason of such default or breach: 
 15.2.1. Continue Lease. Pursue the remedy described in California Civil Code Section 1951.4 whereby Landlord may continue this Lease in full force and effect after Tenant’s breach and
recover the Rent and any other monetary charges as they become due, without terminating Tenant’s right to sublet or assign this Lease, subject only to reasonable limitations as herein provided. During the period Tenant is in default, Landlord
shall have the right to do all acts necessary to preserve and maintain the Premises as Landlord deems reasonable and necessary. 
 15.2.2. Perform. Pay or perform such obligation due (but shall not be obligated to do so), if Tenant fails to pay or perform any obligations when due under this Lease within the time permitted for
their payment or performance. In such case, the costs incurred by Landlord in connection with the performance of any such obligation will be Additional Rent due under this Lease and will become due and payable on demand by Landlord. 

15.2.3. Terminate. Terminate Tenant’s rights to possession by any lawful means, in which case this Lease shall terminate and
Tenant shall immediately surrender possession of the Premises to Landlord. In such event Landlord shall be entitled to recover from 

  
 19 

 
Tenant all damages incurred by Landlord by reason of Tenant’s default, including, without limitation, the following: (A) the worth at the time of award of any unpaid Rent which had been
earned at the time of such termination; plus (B) the worth at the time of award of the amount by which the unpaid Rent which would have been earned after termination until the time of award exceeds the amount of such Rent loss that is proved
could have been reasonably avoided; plus (C) the worth at the time of award of the amount by which the unpaid Rent for the balance of the Term after the time of award exceeds the amount of such Rent loss that is proved could be reasonably
avoided; plus (D) any other amount necessary to compensate Landlord for all the detriment proximately caused by Tenant’s failure to perform its obligations under this Lease or which in the ordinary course of events would be likely to
result therefrom; plus (E) at Landlord’s election, such other amounts in addition to or in lieu of the foregoing as may be permitted from time to time by applicable State law. Upon any such termination of Tenant’s possessory interest
in and to the Premises, Tenant (and at Landlord’s sole election, Tenant’s sublessees) shall no longer have any interest in the Premises, and Landlord shall have the right to make any reasonable repairs, alterations or modifications to the
Premises which Landlord in its sole discretion deems reasonable and necessary. The “worth at the time of award” of the amounts referred to in subparagraphs (A) and (B) above is computed by allowing interest at the maximum rate an
individual is permitted by law to charge. The worth at the time of award of the amount referred to in subparagraph (C) above is computed by discounting such amount at the discount rate of the Federal Reserve Bank of San Francisco at the time of
award plus one percent (1%). 
 15.2.4. Additional Remedies. Pursue any other legal or equitable remedy available to
Landlord. Unpaid installments of Rent and other unpaid monetary obligations of Tenant under the terms of this Lease shall bear interest from the date due at the Interest Rate. 
 15.3. Intentionally Deleted. 
 15.4. Continue. Even though Tenant has
breached this Lease and abandoned the Premises, this Lease shall continue in effect for so long as Landlord does not terminate Tenant’s right to possession, and Landlord may enforce all its rights and remedies under this Lease, including the
right to recover Rent as it becomes due under this Lease. Acts of maintenance or preservation, efforts to relet the Premises, or the appointment of a receiver upon initiative of Landlord to protect Landlord’s interest under this Lease, shall
not constitute a termination of Tenant’s right to possession. 
 15.5. Tenant’s Exercise Rights. In the event
Tenant is in default beyond applicable notice and cure periods under any provision of this Lease then, at Landlord’s sole election, Tenant shall not have the right to exercise any available right, option or election under this Lease.

 16. Default by Landlordd. Landlord shall not be in default under this Lease unless Landlord, or the
holder of any mortgage, deed of trust or ground lease covering the Premises, fails to perform obligations required of Landlord within a reasonable time, but in no event later than thirty (30) days after written notice by Tenant to Landlord
certified mail, postage prepaid, and to the holder of any first mortgage, deed of trust or ground lease covering the Premises whose name and address shall have been furnished to Tenant in writing, specifying wherein Landlord has failed to perform
such obligations; provided, however, that if the nature of Landlord’s obligation is such that more than thirty (30) days are required for performance, then Landlord shall not be in default if Landlord or the holder of any such mortgage,
deed of trust or ground lease commences performance within such 30-day period and thereafter diligently prosecutes the same to completion. Except for the express termination rights set forth in this Lease, in
no event shall Tenant be entitled to terminate this Lease by reason of Landlord’s default, and Tenant’s remedies shall be limited to an action for monetary damages at law and/or injunctive relief. 

17. Security Deposit. On the Commencement Date, Tenant shall deliver to Landlord cash in the amount specified as the
Security Deposit in the Basic Lease Information. The Security Deposit shall be held by Landlord as security for the performance by Tenant of all of the provisions of this Lease. If Tenant fails to pay Rent or other charges due hereunder, or
otherwise defaults with respect to any provision of this Lease, Landlord may use, apply or retain all or any portion of the Security Deposit for the payment of any Rent or other charge in default, or the payment of any other sum to which Landlord
may become obligated by reason of Tenant’s default, or to compensate Landlord for any loss or damage which Landlord may suffer thereby. 

  
 20 

 
If Landlord so uses or applies all or any portion of the Security Deposit, then within ten (10) days after demand therefor Tenant shall deposit cash with Landlord in an amount sufficient to
restore the deposit to the full amount thereof, and Tenant’s failure to do so shall be a material breach of this Lease. Landlord shall not be required to keep the Security Deposit separate from its general accounts. The Security Deposit, or so
much thereof as has not theretofore been applied by Landlord, shall be returned to Tenant without payment of interest for its use (or, at Landlord’s option to the last assignee, if any, of Tenant’s interest hereunder) within thirty
(30) days after the expiration or earlier termination of this Lease, and after Tenant has vacated the Premises. No trust relationship is created herein between Landlord and Tenant with respect to the Security Deposit. In lieu of the cash
Security Deposit described above, the Security Deposit may be in the form of an irrevocable letter of credit (the “Letter of Credit”), issued to Landlord, as beneficiary, in form and substance reasonably satisfactory to Landlord, by a bank
reasonably approved by Landlord, in which case, the Letter of Credit shall serve as the Security Deposit under this Lease. Tenant shall maintain the Letter of Credit for the entire Term, provided that Tenant may at any time substitute a cash
Security Deposit for the Letter of Credit, and upon such substitution, Landlord shall return the Letter of Credit to Tenant. The Letter of Credit shall provide that it will be automatically renewed until thirty (30) days after the expiration of
this Lease unless the issuer provides Landlord with written notice of non-renewal at the notice address herein at least sixty (60) days prior to the expiration thereof. If, not later than thirty (30) days prior to the expiration of the
Letter of Credit, Tenant fails to furnish Landlord with a replacement Letter of Credit pursuant to this section, Landlord shall have the right to draw the full amount of the Letter of Credit, and shall hold the proceeds of the Letter of Credit as a
cash Security Deposit pursuant to this Section 17 of the Lease. Except as set forth in the preceding sentence, Landlord shall only draw upon the Letter of Credit following an event of default and only to the extent required to cure the default.
If Landlord draws upon the Letter of Credit solely due to Tenant’s failure to renew the Letter of Credit at least thirty (30) days before its expiration (i) such failure to renew shall not constitute a default hereunder and
(ii) Tenant shall at any time thereafter be entitled to provide Landlord with a replacement Letter of Credit that satisfies the requirements hereunder, at which time Landlord shall return the cash proceeds of the original Letter of Credit drawn
by Landlord. 
 18. Estoppel Certificate. 

18.1. Obligation to Execute Estoppel. Tenant shall within ten (10) days after notice from Landlord, execute, acknowledge and
deliver to Landlord a statement certifying (i) that this Lease is unmodified and in full force and effect (or, if modified, stating the nature of such modification and certifying that this Lease, as so modified, is in full force and effect),
(ii) the amount of the Rent and the Security Deposit, (iii) the date to which the Rent has been paid, (iv) acknowledging that there are not, to Tenant’s knowledge, any uncured defaults on the part of Landlord hereunder, or
specifying such defaults, if any are claimed, and (v) such other matters as may reasonably be requested by Landlord. Any such statement may be conclusively relied upon by Landlord and any prospective purchaser or encumbrancer of the Building.

 18.2. Failure to Execute Estoppel. Tenant’s failure to deliver such statement within such time shall be
conclusive upon Tenant that (i) this Lease is in full force and effect, without modification except as may be represented by Landlord, (ii) there are no uncured defaults in Landlord’s performance, and (iii) not more than one
month’s Base Rent has been paid in advance. 
 18.3. Financial Statements. If Landlord desires to sell all or any
portion of its interest in the Building or the Project or to finance or refinance the Building or the Project, Tenant agrees to deliver to Landlord and any lender or prospective purchaser designated by Landlord such financial statements of Tenant as
may be reasonably required by Landlord or such lender or prospective purchaser and are then maintained by Tenant in the normal course of Tenant’s business and accounting practices. All such financial statements shall be received by Landlord in
confidence and shall be used for the purposes herein set forth. In addition, within ten (10) days after Landlord’s written request, but not more frequently than once in any twelve (12) month period, Tenant shall deliver to Landlord
Tenant’s most current annual financial statements audited by Tenant’s certified public accountant. If audited financial statements are not available, Tenant shall deliver to Landlord Tenant’s financial statements certified to be true
and correct by Tenant’s chief financial officer. Tenant’s annual financial statements shall not be dated more than twelve (12) months prior to the date of Landlord’s request. Notwithstanding the foregoing provisions of this
Section 18.3, for so long as Tenant remains subject to the periodic 

  
 21 

 
reporting requirements of the Securities Exchange Act of 1934, as amended (the “’34 Act”), Tenant’s obligation to provide financial statements shall be deemed satisified by
Tenant making its required filings under the ’34 Act. 
 19. Subordination. This Lease, at Landlord’s
sole option, shall be subordinate to any ground lease, mortgage, deed of trust, or any other hypothecation for security now or hereafter placed upon the Building and to any and all advances made on the security thereof and to all renewals,
modifications, consolidations, replacements, refinancings and extensions thereof. Notwithstanding such subordination, Tenant’s right to quiet possession of the Premises shall not be disturbed if Tenant is not in default beyond applicable notice
and cure periods and so long as Tenant shall pay the Rent and observe and perform all of the provisions of this Lease, unless this Lease is otherwise terminated pursuant to its terms. If any mortgagee, trustee or ground lessor shall elect to have
this Lease prior to the lien of its mortgage, deed of trust or ground lease, and shall give notice thereof to Tenant, this Lease shall be deemed prior to such mortgage, deed of trust, or ground lease, whether this Lease is dated prior to or
subsequent to the date of said mortgage, deed of trust or ground lease or the date of recording thereof. If any mortgage or deed of trust to which this Lease is subordinate is foreclosed or a deed in lieu of foreclosure is given to the mortgagee or
beneficiary, Tenant shall attorn to the purchaser at the foreclosure sale or to the grantee under the deed in lieu of foreclosure; if any ground lease to which this Lease is subordinate is terminated, Tenant shall attorn to the ground lessor. Tenant
agrees to execute any documents reasonably required to effectuate such subordination or to make this Lease prior to the lien of any mortgage, deed of trust or ground lease, as the case may be, or to evidence such attornment. Any such document of
attornment shall also provide that the successor shall not disturb Tenant in its use of the Premises in accordance with this Lease. Further, the subordination of this Lease to any future ground lease or instrument of security shall be conditioned
upon Tenant’s receipt from any such ground lessors or lenders of a commercially reasonable agreement recognizing Tenant’s rights under the Lease in the event of a foreclosure of the lender’s security interest or termination of the
ground lease. In addition, Landlord shall use good faith efforts to assist Tenant in obtaining a commercially reasonable subordination, non-disturbance and attornment agreement with the existing lender for the Building. 

20. Attorneys’ Fees. In any action or proceeding which Landlord or Tenant brings against the other party in order to
enforce its respective rights hereunder or by reason of the other party failing to comply with all of its obligations hereunder, whether for declaratory or other relief, the unsuccessful party therein agrees to pay all costs incurred by the
prevailing party therein, including reasonable attorneys’ fees, to be fixed by the court, and said costs and attorneys’ fees shall be made a part of the judgment in said action. A party shall be deemed to have prevailed in any action
(without limiting the definition of prevailing party) if such action is dismissed upon the payment by the other party of the amounts allegedly due or the performance of obligations which were allegedly not performed, or if such party obtains
substantially the relief sought by such party in the action, regardless of whether such action is prosecuted to judgment. 

21. Notices. All notices, consents, demands, and other communications from one party to the other given pursuant to the
terms of this Lease shall be in writing and shall be personally delivered, delivered by courier service, delivered by national overnight delivery service (e.g., Federal Express, Airborne Express and UPS), or deposited in the United States mail,
certified or registered, postage prepaid, return-receipt requested, and addressed as follows: To Tenant at the address specified in the Basic Lease Information or to such other place as Tenant may from time to time designate in a notice to Landlord;
to Landlord at the address specified in the Basic Lease Information, or to such other place and to such other parties as Landlord may from time to time designate in a notice to Tenant. All notices personally delivered or delivered by courier shall
be deemed received upon delivery or refusal of delivery, and any notice required under this Lease that is sent by mail shall be deemed received, if properly addressed, three (3) business days after any such notice is deposited in the United
States mail as required herein. 
 22. General Provisions. 

22.1. Applicable Law. This Lease shall be governed by and construed in accordance with the internal laws of the State of
California, notwithstanding any choice of law statutes, regulations, provisions or requirements to the contrary. 

  
 22 

 22.2. Severability. The invalidity of any provision of this Lease, as determined by a
court of competent jurisdiction, shall in no way affect the validity of any other provision hereof. 
 22.3. Waiver. No
waiver of any provision hereof by either party shall be deemed by the other party to be a waiver of any other provision, or of any subsequent breach of the same provision. Landlord’s or Tenant’s consent to, or approval of, any act shall
not be deemed to render unnecessary the obtaining of Landlord’s or Tenant’s consent to, or approval of, any subsequent act by the other party. 
 22.4. Holdover. Should Tenant, or any of its successors in interest, hold over in the Premises, or any part thereof, after the expiration of the Term unless otherwise agreed to in writing, such
holding over shall constitute and be construed as tenancy from month-to-month only, at a monthly rent equal to one hundred fifty percent (150%) of the Base Rent owed during the final year of the Term, as the same may have been extended,
together with the Additional Rent due under this Lease. The inclusion of the preceding sentence shall not be construed as Landlord’s permission for Tenant to hold over. Subject to the provisions of this Lease restricting assignment or
subletting by Tenant, this Lease shall bind the parties, their personal representatives, successors and assigns. 
 22.5.
Entry. Upon one (1) business day prior notice to Tenant (which notice shall not be required in the event of an emergency), Landlord and Landlord’s representatives and agents shall have the right to enter the Premises during regular
business hours for the purpose of inspecting the same, showing the same to prospective purchasers or lenders, and making such alterations, repairs, improvements, or additions to the Premises, the Building or the Common Areas as Landlord may deem
necessary or desirable. Landlord may at any time during the last nine (9) months of the Term place on or about the Premises any ordinary “For Lease” sign. Landlord may at any time place on or about the Premises any ordinary “For
Sale” sign. Any entry by Landlord and Landlord’s agents shall not impair Tenant’s operations more than reasonably necessary, and shall comply with Tenant’s reasonable security measures. 

22.6. Subleases. The voluntary or other surrender of this Lease by Tenant, the mutual cancellation thereof or the termination of
this Lease by Landlord as a result of Tenant’s default shall, at the option of Landlord, terminate all or any existing subtenancies or may, at the option of Landlord, operate as an assignment to Landlord of any or all of such subtenancies.

 22.7. Limitation of Liability. In the event that Landlord or any successor owner of the Building sells or conveys the
Building, then all liabilities and obligations of Landlord or the successor owner under this Lease accruing after the sale or conveyance shall terminate and become binding on the new owner, and Tenant shall release Landlord from all liability under
this Lease (including, without limitation, the Security Deposit), except for acts or omissions of Landlord occurring prior to such sale or conveyance. Tenant expressly agrees that (i) the obligations of Landlord shall not constitute personal
obligations of the officers, directors, partners, employees, affiliates, joint venturers, members, trustees, owners, shareholders, or other principals, agents or representatives of Landlord (“Member of Landlord”), and (ii) Tenant
shall have recourse only to the amount of Landlord’s interest in the Project for the satisfaction of such obligations and not against the other assets of Landlord, including all sales, insurance condemnation and rental proceeds thereof. In this
regard, Tenant agrees that in the event of any actual or alleged failure, breach or default by Landlord of its obligations under this Lease, that (i) no Member of Landlord shall be sued or named as a party in any suit or action (except as may
be necessary to secure jurisdiction of Landlord), (ii) no judgment will be taken against any Member of Landlord, and any judgment taken against any Member of Landlord may be vacated and set aside at any time without hearing, (iii) no writ
of execution will ever be levied against the assets of any Member of Landlord, and (iv) these agreements by Tenant are enforceable both by Landlord and by any Member of Landlord. 

22.8. Authority. Tenant represents and warrants that the individual executing this Lease on behalf of Tenant is duly authorized to
execute and deliver this Lease on behalf of the corporation, company or partnership in accordance with, where applicable, a duly adopted resolution of the board of directors of the corporation, the vote of the members of the limited liability
company or the vote of the partners within the partnership, and that this Lease is binding upon the corporation, company or partnership in accordance with its respective articles of incorporation and bylaws, operating agreement or partnership
agreement. 

  
 23 

 22.9. Time. Time is expressly declared to be of the essence of this Lease and of each
and every covenant, term, condition, and provision hereof. 
 22.10. Joint and Several Liability. If there is more than
one party comprising Tenant, the obligations imposed on Tenant shall be joint and several. 
 22.11. Construction. The
language in all parts of this Lease shall be in all cases construed as a whole according to its fair meaning and not strictly for nor against either Landlord or Tenant. 
 22.12. Definitions. As used in this Lease and whenever required by the context thereof, each number, both singular and plural, shall include all numbers and in each gender shall include all
genders. Landlord and Tenant, as used in this Lease or in any other instrument referred to in or made a part of this Lease, shall likewise include both the singular and the plural, a corporation, limited liability company, partnership, individual or
person acting in any fiduciary capacity as executor, administrator, trustee or in any other representative capacity. 
 22.13.
Exhibits. The Basic Lease Information, Exhibits and Addendum attached to this Lease and incorporated herein by reference thereto. 
 22.14. Force Majeure. Any delay in construction, repairs, or rebuilding any building, improvement or other structure herein shall be excused and the time limit extended to the extent that the delay
is occasioned by reason of acts of God, labor troubles, laws or regulations of general applicability, acts of Tenant or Tenant Delays (as the term is defined in the Work Letter
Agreement—3rd Floor), or other occurrences beyond the
reasonable control of Landlord. Accordingly, Landlord’s obligation to perform shall be excused for the period of the delay and the period for performance shall be extended for a period equal to the period of such delay, provided such delay
shall not delay any of Tenant’s rent abatement or termination rights. 
 22.15. Broker’s Fee. Each party
represents that it has not had dealings with any real estate broker, finder or other person, with respect to this Lease in any manner, except the brokerage firm(s) specified in the Basic Lease Information. Each party shall hold harmless the other
party from all damages resulting from any claim that may be asserted against the other party by any other broker, finder, or other person claiming by, through or under such party. Landlord shall pay any commissions or fees that are payable to the
broker or finder specified in the Basic Lease Information, with respect to this Lease in accordance with the provisions of a separate commission contract. 
 22.16. Intentionally Deleted 
 22.17. Entire Agreement. This Lease,
including attached Exhibits, Addendum, and Basic Lease Information, contains all agreements and understandings of the parties and supersedes and cancels any and all prior or contemporaneous written or oral agreements, instruments, understandings,
and communications of the parties with respect to the subject matter herein. This Lease, including the attached Exhibits, Addendum, and Basic Lease Information, may be modified only in a writing signed by each of the parties. The Exhibits, Addendum
and Basic Lease Information attached to this Lease are incorporated herein by reference. 
 22.18. Approvals. Whenever
this Lease requires an approval, consent, determination or judgment by either Landlord or Tenant, unless another standard is expressly set forth, such approval, consent, determination or judgment and any conditions imposed thereby shall be
reasonable and shall not be unreasonably withheld or delayed. 
 22.19. Reasonable Expenditures. Any expenditure by a
party permitted or required under this Lease, for which such party demands reimbursement from the other party, shall be limited to the fair market value of the goods and services involved, shall be reasonably incurred, and shall be substantiated by
documentary evidence available for inspection and review by the other party. 
 22.20. Remeasurement. Landlord shall have
its architect measure the Building and the Premises upon completion of construction and shall promptly provide written notice of such measurements to Tenant. Tenant shall have the one-time right, within thirty (30) following receipt of such
notice, to verify the square footage by an architect that is reasonably acceptable to Landlord and Tenant, using the ANSI/BOMA-Z65.1-2010 measurement standard. In any event, 

  
 24 

 
if the rentable square footage of the Premises or Building is different than that set forth in this Lease, the Base Rent, Tenant’s Percentage Share and the Security Deposit shall be adjusted
to reflect the actual square footage; provided, however, in no event shall the rentable square footage of the Premises be deemed to be more than 105% of the amount set forth in the Basic Lease Information. 

22.21. Addendum. The Addendum attached hereto is incorporated herein by reference. If no Addendum, state “none” in the
following space:            . 
 [SIGNATURE TO APPEAR ON FOLLOWING
PAGE] 

  
 25 

 IN WITNESS WHEREOF, the parties have executed this Lease on the date first mentioned above.

  

													
	“Landlord”	 	“Tenant”
		
	 REDWOOD BUSINESS CENTER 1 LLC,
 a California limited liability company
	 	 CYAN, INC.,

a Delaware corporation doing business as Cyan

California

			
	By:	 	Redwood Technology Center, LLC	 	
		 	a California limited liability company	 		 	
		 	Its: Manager and Sole Member	 	By:	 	 /s/ Michael Zellner

		 		 		 		 		 	Name:	 	Michael Zellner
		 	  
 By:
	 	  
 G&W Ventures, LLC
	 		 	Its:	 	CFO
		 		 	a California limited liability company	 		 		 	
		 		 	Its: Manager	 		 		 	
		 		 		 		 		 	
		 		 		 	By:	 	  

		 		 	By:	 	 /s/ Matthew T. White
 Matthew T. White, Manager
	 		 	 Name:
 Its:
	 	  
  

  

			
	AMERIVINE TOWN CENTER, LLC,
	a California limited liability company
		
	By:	 	Amerivine Inc.,
	a California corporation
	Its:	 	Sole Member
		
	By:	 	 /s/ David F. Coleman

		 	David F. Coleman
	Its:	 	President

  
 26 

 ADDENDUM 
 23. Base Rent. The Base Rent during the Term shall be as follows: 
  

							
	 Lease Year
	  	Square Footagea	  	Monthly Base Rent
Per Sq. Ft.	  	Monthly Base Rent
	 Year 1
	  	20,005	  	$2.30	  	$46,011.50
	 Year 2 (months 1-6)
	  	20,005	  	$2.37	  	$47,411.85
	 Year 2 (months 7-12)b
	  	38,778	  	$2.37	  	$91,903.86
	 Year 3
	  	38,778	  	$2.44	  	$94,618.32c

 aRent is calculated based on rentable square footage of
20,005 for the third floor of the Building and 18,773 for the second floor of the Building. Such square footages are subject to adjustment as provided in Section 22.20. 

bThe date that Tenant commences paying rent for the second
floor of the Building is estimated and shall be adjusted to the actual date pursuant to Section 27 below. In addition, rent may commence for the second floor of the Building in phases pursuant to such section. 

cFor Lease Years 4 through 10, Base Rent shall be increased
3% from the prior Lease Year. 
 24. Option to Extend. 

 

	 	a.	Exercise of Option. 

Tenant shall have an option to extend the term of the lease on all the provisions contained in this Lease, except for Base Rent, and the
Base Year, which shall be adjusted to 2024, for one five (5) year period (the “Extended Term”) following expiration of this Term, by giving notice of exercise of the option (“Option Notice”) to Landlord at least twelve
(12) months before but not more than eighteen (18) months before the expiration of the Term. Provided that, if Tenant is in default beyond applicable notice and cure periods on the date of giving the option notice, the Option Notice shall
be totally ineffective. 
 Base Rent for the Extended Term shall be at the then current Fair Market Rental Rate (defined below)
determined as set forth below. 
 Tenant shall have no other right to extend the term beyond the Extended Term. 

 

	 	b.	Determination of Fair Market Rent. 

  

	 	(1)	 Agreement on Rent. For the purposes of this Lease, the “Fair Market Rental Rate” means the monthly base rent (i.e., rent other than
operating expenses, taxes and insurance premiums) expected to prevail as of the commencement of an Extended Term for the entire Extended Term (including appropriate increases) for the Premises, based on leases of comparable space in the vicinity of
the Project of a quality and with interior improvements, parking, site amenities, building systems, location, identity and access all comparable to that of the Premises, for a term equal to the Extended Term. Fair Market Rental Rate shall take into
account Tenant’s obligations to pay additional rent under this Lease and that there will be no free rent, tenant improvement allowance or other concessions during the Extension Term under this Lease, but will not take into consideration any
alterations installed in the Premises at Tenant’s expense. Within fifteen (15) days after Landlord’s receipt of Tenant’s Option Notice, by written notice to Tenant (“Landlord’s Rent Notice”), Landlord

  
 Addendum,
Page 1 

	 	
shall advise Tenant as to Landlord’s determination of the Fair Market Rental Rate. If Tenant disagrees with Landlord’s determination, Tenant shall advise Landlord as to Tenant’s
determination of Fair Market Rental Rate by written notice (“Tenant’s Rent Notice”) within fifteen (15) days after Tenant’s receipt of Landlord’s Rent Notice. If Tenant fails to deliver Tenant’s Rent Notice to
Landlord within the time period provided above, Tenant shall be bound by Landlord’s determination of the Fair Market Rental Rate as set forth in Landlord’s Rent Notice. If Tenant shall timely deliver to Landlord Tenant’s Rent Notice,
Landlord and Tenant shall attempt in good faith to reach agreement as to the Fair Market Rental Rate within fifteen (15) days after Landlord’s receipt of Tenant’s Rent Notice. 

 

	 	(2)	Selection of Brokers. If Landlord and Tenant are unable to agree as to the amount of the Fair Market Rental Rate within the aforementioned fifteen (15) day
period as evidenced by a written amendment to this Lease executed by them, then, within ten (10) days after the expiration of the fifteen (15) day period, Landlord and Tenant shall each, at its sole cost and by giving notice to the other
party, appoint a competent real estate broker licensed in California with at least five (5) years’ full-time commercial real estate leasing experience in Sonoma County to determine the Fair Market Rental Rate. If either Landlord or Tenant
does not appoint a broker within ten (10) days after the other party has given notice of the name of its broker, the single broker appointed shall be the sole broker and shall determine the Fair Market Rental Rate. If Landlord and Tenant as
stated in this Section appoint two (2) brokers, they shall attempt to select a third broker meeting the qualifications stated in this Section within ten (10) days. If they are unable to agree on the third broker, either Landlord or Tenant,
by giving ten (10) days’ notice to the other party, can apply to the then president of the real estate board of the county in which the Building is located, or to the Presiding Judge of the Superior Court of the county in which the
Building is located, for the selection of a third broker who meets the qualifications stated in this paragraph. Landlord and Tenant each shall bear one-half (1/2) of the cost of appointing the third broker and of paying the third broker’s
fee. The third broker, however selected, shall be a person who has not previously acted in any capacity for either Landlord or Tenant. 

  

	 	(3)	Value Determined By Three (3) Brokers. The brokers shall determine the Fair Market Rental Rate by using the “Market Comparison Approach” with the
relevant market being office buildings located in the City of Petaluma. Within thirty (30) days after the selection of the third broker, Landlord’s broker shall arrange for the simultaneous delivery to Landlord of written appraisals from
each of the brokers and the three (3) appraisals shall be added together and their total divided by three (3); the resulting quotients shall be the Fair Market Rental Rate. If, however, the low appraisal and/or the high appraisal of the Fair
Market Rental Rate are/is more than ten percent (10%) lower and/or higher than the middle appraisal, the low appraisal and/or the high appraisal shall be disregarded. If only one (1) appraisal is disregarded, the remaining two
(2) appraisals shall be added together and their total divided by two (2); the resulting quotient shall be the Fair Market Rental Rate. If both the low appraisal and the high appraisal of the Fair Market Rental Rate is/are disregarded as stated
in this Section, the middle appraisal shall be the Fair Market Rental Rate. 

  

	 	c.	Notice to Landlord and Tenant; Lease Amendment. 

 After the monthly Base Rent for an Extended Term has been set, Landlord and Tenant immediately shall execute an amendment to the Lease stating the monthly Base Rent. 

  
 Addendum,
Page 2 

 25. Building Construction. Promptly following the date of
this Lease, Landlord shall commence with the final design and permitting for the Building, and shall thereafter diligently construct the Building in a good and workmanlike manner, in compliance with all laws and in substantial compliance with the
plans therefor approved by Landlord and Tenant. The design of the Building shall be substantially the same as the current design previously approved by the City of Petaluma, but shall include an enclosed bridge between the third floor of the
Building and the adjacent building located at 1383 North McDowell Blvd. (with such bridge design and location to be determined solely by Landlord following consultation with Tenant so long as the bridge is enclosed). Tenant acknowledges that
Landlord will have to obtain design review approval for the bridge between the 2nd and 3rd
floors. The cost of all such work, including design, engineering, permitting and construction costs, shall be borne by Landlord; provided that Landlord shall construct the Building to the same design standards and criteria as the adjacent
building located at 1383 North McDowell Blvd., but will, to the extent allowed by the City of Petaluma, not enclose the exterior stairwells between the 2nd and 3rd floors. As used in this Lease, the term “Warm Shell” shall mean the structure, floor slabs, elevators,
stairs, roof and exterior glazing and facade of the Building (including the structure, floor slab, roof and exterior glazing and facade of the enclosed bridge) with the following services installed in, and distributed to the core of each floor of,
the Building and, as applicable, with connections for horizontal extensions within the tenant demised areas: water, sewer, electrical, fire, life safety and HVAC. The date upon which Landlord has substantially completed construction of the Warm
Shell shall be referred to as the “Warm Shell Completion Date”. 
 26. Condition Precedent. Landlord
intends to obtain third-party debt financing for a portion of the cost to construct the Building. It shall be a condition precedent to the effectiveness of this Lease that Landlord obtain such financing on terms and conditions acceptable to Landlord
in its sole and absolute discretion. Unless Landlord delivers to Tenant written notice of its failure to obtain such financing by July 31, 2013, this contingency shall be deemed satisfied and waived. 

27. 2nd Floor Rent Commencement. The parties anticipate Tenant desiring to improve and occupy the 2nd Floor Premises on or after the Commencement Date of the Lease. Tenant shall notify Landlord in writing of the date on which Tenant
wishes the Lease to commence as to the 2nd Floor Premises,
which date may not be earlier than the Commencement Date or later than eighteen (18) months after the Commencement Date. The earlier of the date so designated by Tenant and the date that is eighteen (18) months after the Commencement Date
shall be referred to herein as the “2nd Floor Target
Date”. Such notice shall be provided not less than eight (8) months prior to the 2nd Floor Target Date. For the avoidance of doubt, in the absence of any other notice, the 2nd Floor Target Date will be the date that is eighteen (18) months after the Commencement Date. Notwithstanding
anything to the contrary in the Lease or the Work Letter Agreement—2nd Floor, Tenant shall commence paying rent for the 2nd Floor Premises (“2nd Floor Rent Commencement”) on the later of (i) the date Landlord delivers the 2nd
Floor Premises to Tenant in “substantially completed” condition (as defined in Section 11 of the Work Letter Agreement—2nd Floor), and (ii) the 2nd Floor Target Date; provided that if Landlord is ready to deliver the 2nd Floor Premises prior the 2nd Floor Target Date and Tenant elects to take delivery prior to the
2nd Floor Target Date, then the 2nd Floor Rent Commencement shall occur when Landlord delivers the 2nd
Floor Premises to Tenant in “substantially completed” condition (as defined in Section 11 of the Work Letter Agreement—2nd Floor); and provided further that if Tenant elects to have Landlord construct tenant improvements
on a portion (but not all) of the second floor of the Building in phases, then the 2nd Floor Rent Commencement shall apply separately to each such phase. If the
2nd Floor Rent Commencement (as adjusted pursuant to
Section 7 of Exhibit B-2) does not occur by the date that is sixty (60) days after the 2nd Floor Target Date, then Tenant’s obligations to pay rent with respect to the 2nd Floor shall be delayed by one (1) additional day for each day the 2nd Floor Rent Commencement is delayed thereafter. Prior to the 2nd
Floor Rent Commencement, Tenant shall have no responsibility or liability for the 2nd Floor Premises and references in the Lease to Premises shall mean only the 3rd Floor Premises. 

28. Right of First Refusal. So long as no Event of Default has occurred and is then continuing, Tenant shall have a
continuing right of first refusal during the Term to lease any space on the first floor of the Building that becomes available for lease from time to time. If Landlord receives an offer to lease any such space on the first floor of the Building
which Landlord desires to accept (the “Offer”), Landlord shall notify Tenant of the space so offered and the rent and other material terms so offered (the “Offer Notice”). If Tenant desires to exercise 

  
 Addendum,
Page 3 

 
Tenant’s right of first refusal with respect to such space, then within seven (7) business days following Tenant’s receipt of the Offer Notice, Tenant shall deliver notice to
Landlord electing to lease the space so offered on the terms set forth in the Offer Notice. If Tenant elects to lease such space, then Landlord and Tenant shall execute an amendment to the Lease on the terms set forth in the Offer Notice and to the
extent not inconsistent with such notice terms, the terms of the Lease. If Tenant does not respond affirmatively in writing within such seven (7) business day period, Landlord may lease the subject space to a third party on terms not materially
more favorable than the terms presented to Tenant in the Offer Notice. Further, if Landlord does not so execute a lease for the subject space within six (6) months following Tenant’s receipt of the Offer Notice, such space will again be
subject to the provisions of this Section. 
 29. Building Signage. Tenant shall have the right to install, at its
sole cost and expense, one (1) exterior “eye-brow” sign on the westerly façade of the Building. The design, size and specific location of the sign shall be subject to Landlord’s prior written consent, which shall not be
unreasonably withheld. Tenant shall obtain all required building permits and other authorizations from the City of Petaluma and all other agencies having jurisdiction over the Building. The sign shall comply with Landlord’s signage program for
the Building and any applicable codes, laws, ordinances, rules and regulations. Tenant shall maintain the sign in first class condition and repair, including repainting and replacing as reasonably necessary. Tenant shall remove the sign upon the
expiration or earlier termination of the Lease, shall repair any damage to the Building in connection therewith, and shall return the Building to its condition prior the installation of the sign. Without limiting the foregoing, Tenant shall repaint
portions of the Building as necessary to eliminate any “ghosting” or visible outline of the sign’s former location following their removal. Landlord shall bear no cost or expense in connection with Tenant’s exterior sign, and
Tenant shall indemnify, defend (by counsel reasonably acceptable to Landlord) and hold harmless Landlord from any and all claims, demands, liability, damages, judgments, costs and expenses (including reasonable attorneys’ fees) that Landlord
may suffer or incur as a result or arising out of or related to the installation, use, operation, maintenance, replacement and/or removal of the sign, except to the extent due to the negligence, willful misconduct or violation of this Lease by
Landlord. 
 30. Warm Shell. Notwithstanding anything to the contrary in the Lease, including
the addenda and exhibits thereto and notwithstanding any Tenant Delays (as defined in the Work Letters attached hereto as Exhibits B-1 and B-2), under no circumstances shall (a) the Commencement Date or the 2nd Floor Rent Commencement occur prior to the Warm Shell Completion
Date, (b) Tenant be responsible for any insurance or indemnity obligations under the Lease prior to the Warm Shell Completion Date, (c) Tenant be responsible for any costs to construct the Warm Shell or (d) Tenant be entitled to
access the Premises prior to the Warm Shell Completion Date or require Landlord to make changes to the Warm Shell. 

  
 Addendum,
Page 4 

 EXHIBIT A-1 
 DIAGRAM OF PREMISES 
 

 

  
 Exhibit A-1

 EXHIBIT A-2 
 DIAGRAM OF PROJECT 
 

 

  
 Exhibit A-2

 EXHIBIT B-1 

WORK LETTER AGREEMENT – THIRD FLOOR 
 THIS WORK LETTER AGREEMENT – THIRD FLOOR supplements that certain lease (the “Lease”) dated July 2, 2013, executed by REDWOOD BUSINESS CENTER 1 LLC, a California limited liability
company and AMERIVINE TOWN CENTER, LLC, a California limited liability company (collectively, “Landlord”), and CYAN, INC., a Delaware corporation doing business in California as Cyan California (“Tenant”). All capitalized terms
not otherwise defined herein shall have the same meaning as those capitalized terms contained in the Lease. 
 1. Landlord shall be responsible for constructing within the portion of the Premises located on the third floor of the Building (the “3rd Floor Premises”) private offices, open offices, kitchen room, telecommunication closets, conference rooms and
break out rooms (the “3rd Floor Tenant
Improvements”) in the same ratios, with the same design and with the same or equivalent finishes as the space Tenant currently occupies in the portion of the second floor of the adjacent building located at 1383 North McDowell Blvd. added
pursuant to the third amendment to Tenant’s lease thereof. Landlord and Tenant shall work together to prepare a preliminary space plan for such third floor of the Building within 90 days following the execution of the Lease (the
“Preliminary Space Plan”). The 3rd Floor Tenant
Improvements for the 3rd Floor Premises will be more
particularly described in the plans and construction drawings (the “Construction Drawings”) as approved below. Any additional work (the “Third Floor Tenant Extra Improvements”), including without limitation any lab space,
security and access control measures, fixtures, cabling, or telecommunications needs, shall be at Tenant’s sole cost and expense. Upon completion and receipt of the Preliminary Space Plan, Tenant shall within ten (10) business days provide
approval of the Preliminary Space Plan, or, note any exceptions to or desired revisions for the Preliminary Space Plan in a written notice to Landlord. 
 2. Following the completion and approval of the Preliminary Space Plan, Landlord shall arrange for Landlord’s architect to provide to Tenant the Construction Drawings for the 3rd Floor Tenant Improvements and Third Floor Tenant Extra Improvements.
The Construction Drawings shall indicate the specific requirements of the 3rd Floor Premises, outlining in detail interior partitions, floor coverings, a reflected ceiling plan, plumbing fixtures and electrical plans (setting forth the electrical requirements of Tenant), all in
conformity with the Preliminary Space Plan. The Construction Drawings shall include full energy calculations as required by the State of California and the city agencies. Following execution of the Lease and selection of the General Contractor,
Landlord shall also cause to be prepared an estimate of the total cost for the 3rd Floor Tenant Extra Improvements (the “Cost Estimate”), which Cost Estimate shall also conform to or represent logical evolutions of or developments from the Preliminary Space Plan. 

3. Within five (5) business days after receipt of the Construction Drawings and the Cost Estimate, Tenant shall
either approve or disapprove of the Construction Drawings and Cost Estimate by written notice to Landlord. If Tenant disapproves of the Construction Drawings, Tenant shall specify in detail the changes or modifications to the Construction Drawings
or Cost Estimate required by Tenant. Any such request for changes or modifications shall be subject to Landlord’s approval, provided, however, if Tenant desires changes, Landlord shall not unreasonably withhold its approval of such changes and
the parties shall confer and negotiate in good faith to reach agreement on modifications to the Construction Drawings and the Cost Estimate as a consequence of such change. If Landlord approves of Tenant’s proposed change or modification,
Landlord shall arrange for Landlord’s architect to revise the Construction Drawings and resubmit the Construction Drawings to Tenant for its review and approval in accordance with the procedure set forth above. Tenant acknowledges that the
Construction Drawings are subject to the approval of the appropriate government authorities. It shall be Tenant’s responsibility to ensure that the design and function of the 3rd Floor Tenant Improvements and Third Floor Tenant Extra Improvements are suitable for Tenant’s business and needs.
The improvements shall be constructed in a good and workmanlike manner, in accordance with the approved plans and current building standards, laws, regulations, ordinances and codes. Landlord shall not be required to install any 3rd Floor Tenant Improvements or Third Floor Tenant Extra Improvements
which do not conform to the Construction Drawings. If the parties are unable to reach agreement on the Construction Drawings or Cost Estimate within fifteen (15) days following delivery of the Construction Drawings and Cost Estimate to Tenant,
Landlord, Tenant and General Contractor shall meet and discuss in good faith resolution of the cost and design issues until the issues are resolved. 

  
 Exhibit B-1,
Page 1 

 4. Landlord shall furnish and install the 3rd Floor Tenant Improvements and the Third Floor Tenant Extra
Improvements as set forth in the Construction Drawings. The 3rd Floor Tenant Improvements shall be furnished and installed and paid for by Landlord and shall include, but not be limited to, the following: 

(a) The costs of the Preliminary Space Plan and final Construction Drawings (including the cost of one revision only) and engineering
costs associated with completion of the State of California energy utilization calculations under Title 24 legislation; and 

(b) The costs of obtaining building permits and other necessary authorizations from the city, county and the State of California.

 The Tenant Extra Improvements set forth on the final Construction Drawings shall be paid for by Tenant, except as provided
below. Tenant shall have no obligations to restore any of the Tenant Improvements or Tenant Extra Improvements. 
 Tenant shall
pay for all Third Floor Tenant Extra Improvements within thirty (30) days following receipt of Landlord’s written demand therefor, which demand(s) may be submitted to Tenant prior to commencement of construction of the Third Floor Tenant
Extra Improvements based on Landlord’s estimate of such costs. If Tenant fails to pay within such thirty-day period, Landlord may, in addition to all other available remedies, (i) delay the commencement of construction of the Third Floor
Tenant Extra Improvements if such work has not commenced, or (ii) stop construction of the Third Floor Tenant Extra Improvements if such work has commenced, in either case until such time as Tenant has paid Landlord for all Third Floor Tenant
Extra Improvements for which Tenant has received a written demand from Landlord. 
 5. In no event shall
the 3rd Floor Tenant Improvements payable by Landlord include (i) the costs of procuring or installing any trade fixtures, equipment, furniture, furnishings, telephone or computer equipment or wiring or other personal property (“Personal
Property”) or (ii) any Change Orders (as the term is defined in Paragraph 6 below) requested by Tenant or related to 3rd Floor Tenant Extra Improvements, which increase the cost of construction of the Third Floor Tenant Improvements. Such
items shall be paid by Tenant. 
 6. After the Construction Drawings have been approved by Landlord and
Tenant as provided above, neither party shall have the right to require extra work or changes to the work provided that neither party will unreasonably withhold its consent to changes required by the City of Petaluma or any other governmental body
with jurisdiction. However, following Tenant’s approval of the Construction Drawings, Tenant may request changes or modifications thereto (“Change Order”), however, the cost of any Change Order(s) which increase the total construction
costs shall be borne by Tenant in the amount set forth in the approved Change Order. If Tenant shall request any Change Order, then Landlord shall promptly give Tenant a written estimate of (a) the cost of engineering and design services to
prepare the Change Order, (b) the cost of work to be performed pursuant to the Change Order, and (c) the time delay in substantial completion of the Premises expected because of such requested Change Order. Within three (3) days after
Tenant’s receipt of the written estimate, Tenant shall notify Landlord in writing whether it approves the written estimate. Within thirty (30) days after Landlord’s submission to Tenant of any invoice for costs incurred in connection
with such Change Order, Tenant shall pay the same to Landlord if such Change Order increases the cost of construction. If such written authorization is not received by Landlord, then Landlord shall not be obligated to commence work on the 3rd Floor Premises and Tenant shall be responsible for any delay in the
completion of the 3rd Floor Premises in accordance with
Paragraph 7 below. 
 7. If the Commencement Date of the Lease has not occurred on or before the Estimated Commencement Date,
and if the cause of the delay in the occurrence of the Commencement Date is attributable to Tenant, then the Lease shall begin on the date the Commencement Date otherwise would have occurred but for the Tenant delays (“Tenant Delays”).
Tenant Delays shall mean delays in substantial completion of the improvements beyond the Estimated Commencement Date caused by (a) Tenant’s failure to approve the Construction Drawings within the time period noted above,
(b) Tenant’s request for special materials not available when needed for construction in accordance with the construction schedule, (c) Change Orders, (d) Tenant’s or Tenant’s agents’ interference with
Landlord’s work 

  
 Exhibit B-1,
Page 2 

 
(provided that there shall be a grace period for the first two (2) days of interference, which shall not constitute Tenant Delays), and (e) Tenant’s failure to pay for Tenant
Improvements and Tenant Extra Improvements within the time period noted above. To the extent practicable, Landlord shall promptly notify Tenant of any interference with Landlord’s work by Tenant or Tenant’s agent. 

8. Tenant may, with Landlord’s written consent, enter the 3rd Floor Premises subsequent to the Warm Shell Completion Date but
prior to the Commencement Date solely for the purpose of installing its Personal Property, cabling, and telecommunications equipment in the 3rd Floor Premises, as long as such entry will not interfere with the orderly construction and completion of the 3rd Floor Premises (hereinafter, “Tenant’s Work”). Such
entry shall be subject to all of the terms of the Lease except the obligation to pay Rent. Tenant shall notify Landlord of its desired time(s) of entry and shall submit for Landlord’s written approval the scope of the Tenant’s Work to be
performed and the name(s) of the contractor(s) who will perform such work. Tenant agrees to indemnify, defend and hold harmless Landlord and any mortgagee, ground lessor or beneficiary of a deed of trust encumbering, secured by or affecting the
3rd Floor Premises or the Building, from and against any
and all claims, actions, losses, liabilities, damages, costs or expenses (including, without limitation, reasonable attorneys’ fees and claims for worker’s compensation) of any nature whatsoever, arising out of or in connection with the
Tenant’s Work (including, without limitation, claims for breach of warranty, personal injury or property damage) except to the extent due to the negligence, willful misconduct or violation of this Lease by Landlord. 

9. During the course of installation of Tenant’s Work, at Tenant’s expense, Tenant shall obtain or maintain public liability
and worker’s compensation insurance, in amounts acceptable to Landlord, and which name Landlord and Tenant as parties insured from and against any and all liability for death of or injury to person or damage to property caused in or about or by
reason of the construction of the Tenant’s Work. 
 10. Landlord shall not be liable for any latent or
patent defects therein, except that Landlord warrants the
3rd Floor Premises against defects and violations of law
with respect to the original construction of the 3rd Floor
Tenant Improvements for a period of two (2) years from the date of substantial completion (the “Warranty Period”). 
 11. The 3rd
Floor Premises shall be deemed “substantially completed” as of the date that all of the following conditions are satisfied: 
 (a) The 3rd
Floor Tenant Improvements and Tenant Extra Improvements have been substantially completed in accordance with the approved Construction Drawings (except for those punch list items referenced in Paragraph 12 below), such that Tenant can reasonably
conduct business within the 3rd Floor Premises;

 (b) A certificate of occupancy and/or finalized building permit has been issued for the 3rd Floor Premises; and 

(c) All building facilities and systems, including electrical, plumbing, and mechanical, serving the 3rd Floor Premises, shall be in good operating order. 

12. Tenant’s acceptance of the 3rd Floor Premises shall not be deemed a waiver of Tenant’s right to have defects in the 3rd Floor Premises repaired at no cost to Tenant during the Warranty
Period. Tenant, assisted by Landlord’s architect, shall inspect the 3rd Floor Premises immediately prior to occupancy and compile and furnish Landlord with a punch list of any missing or deficient 3rd Floor Tenant Improvements or Third Floor Tenant Extra Improvements. Landlord shall complete the corrective work noted
in the punch list in a prompt, good and workman-like manner. Punch list corrections shall not delay the Commencement Date, nor shall a delay in making corrections be grounds for a delay or reduction in any rent payments due Landlord. Tenant shall
also give notice to Landlord whenever any such defect becomes reasonably apparent during the Warranty Period, and Landlord shall repair any such defect as soon as practicable. 

  
 Exhibit B-1,
Page 3 

 13. All floor area calculations are from the center line of the
partitions and the outside line of the exterior and hall walls. No deduction is allowed for the columns, sprinkler risers, roof drains, or air conditioning units serving Tenant and located within the 3rd Floor Premises. 

14. Landlord shall select the manufacturer and vendor of all building materials and equipment with respect to the
3rd Floor Tenant Improvements and Third Floor Tenant Extra
Improvements to be constructed hereunder. 
 15. Notwithstanding anything to the contrary contained in the
Lease or this Work Letter, Tenant acknowledges and agrees that the 3rd Floor Premises are intended for use by Tenant and the specification and design requirements for the 3rd Floor Tenant Improvements are not within the special knowledge or experience of Landlord.

 16. Tenant shall not mortgage, grant a security interest in or otherwise encumber all or any portion of
the 3rd Floor Tenant Improvements. 

17. Notwithstanding anything in this Lease or Addendum to the contrary, the cost of the Third Floor Tenant Extra Improvements shall not
include (and Landlord shall be solely responsible for) the following: (a) costs to bring the Project into compliance with applicable laws and restrictions; (b) wages, labor and overhead for overtime and premium time; and
(c) management or supervision fees by Landlord other than actual, reasonable fees paid for construction management services (not to exceed 4% of all other hard and soft costs of the Third Floor Tenant Improvements and Third Floor Tenant Extra
Improvements). 
 [SIGNATURES TO APPEAR ON FOLLOWING PAGE] 

  
 Exhibit B-1,
Page 4 

													
	 “Landlord”
	 	 “Tenant”

		
	 REDWOOD BUSINESS CENTER 1 LLC,
 a California limited liability company
	 	 CYAN, INC.,

a Delaware corporation doing business as Cyan California

					
	By:	 	 Redwood Technology Center, LLC
 a California limited liability company
	 		 		 	
		 	Its:	 	Manager and Sole Member	 	By:	 	 /s/ Michael Zellner

		 		 		 		 		 	Name:	 	Michael Zellner
		 	By:	 	 G&W Ventures, LLC
 a California limited liability company
	 		 	Its:	 	CFO
		 		 	Its:	 	Manager	 		 		 	
		 		 		 		 	By:	 	  

		 		 		 		 		 	Name:	 	  

		 		 		 		 		 	Its:	 	  

		 		 	By:	 	 /s/ Matthew T. White
	 		 		 	
		 		 		 	Matthew T. White, Manager	 		 		 	
				
	 AMERIVINE TOWN CENTER, LLC,
 a California limited liability company
	 		 		 	
				
	By: Amerivine Inc.,	 		 		 	
	a California corporation	 		 		 	
	Its: Sole Member	 		 		 	
					
	By:	 	 /s/ David F. Coleman
	 		 		 	
		 	David F. Coleman	 		 		 	
	Its:	 	President	 		 		 	

  
 Exhibit B-1,
Page 5 

 EXHIBIT B-2 

WORK LETTER AGREEMENT – SECOND FLOOR 
 THIS WORK LETTER AGREEMENT – SECOND FLOOR supplements that certain lease (the “Lease”) dated July 2, 2013, executed by REDWOOD BUSINESS CENTER 1 LLC, a California limited liability
company and AMERIVINE TOWN CENTER, LLC, a California limited liability company (collectively, “Landlord”), and CYAN, INC., a Delaware corporation doing business in California as Cyan California (“Tenant”). All capitalized terms
not otherwise defined herein shall have the same meaning as those capitalized terms contained in the Lease. 
 1. Landlord shall be responsible for constructing within the portion of the Premises located on the second floor of the Building (the “2nd Floor Premises”) private offices, open offices, kitchen
rooms, telecommunication closets, conference rooms and break out rooms (the “2nd Floor Tenant Improvements”) in the same ratios, with the same design and with the same or equivalent finishes as the space Tenant currently occupies in the
portion of the second floor of the adjacent building located at 1383 North McDowell Blvd. added pursuant to the third amendment to Tenant’s lease thereof. Landlord and Tenant shall work together to prepare a preliminary space plan for such
second floor of the Building by the date that is eight (8) months prior to the 2nd Floor Target Date (the “Preliminary Space Plan”). The 2nd Floor Tenant Improvements for the 2nd Floor Premises will be more particularly described in the plans and construction drawings (the
“Construction Drawings”) as approved below. Any additional work (the “2nd floor Tenant Extra Improvements”), including without limitation any lab space, fixtures, cabling or telecommunications needs shall be at Tenant’s sole cost and expense. 

2. Following completion and approval of the Preliminary Space Plan, Landlord shall arrange for Landlord’s architect to provide to
Tenant the Construction Drawings for the 2nd Floor Tenant Improvements and 2nd Floor Tenant Extra Improvements. The Construction Drawings shall indicate the specific requirements of the 2nd Floor Premises, outlining in detail interior partitions,
floor coverings, a reflected ceiling plan, plumbing fixtures and electrical plans (setting forth the electrical requirements of Tenant), all in conformity with the Preliminary Space Plan. The Construction Drawings shall include full energy
calculations as required by the State of California and the city agencies. Following execution of the Lease and selection of the General Contractor, Landlord shall also cause to be prepared an estimate of the total cost for the 2nd Floor Tenant
Extra Improvements (the “Cost Estimate”), which Cost Estimate shall also conform to or represent logical evolutions of or developments from the Preliminary Space Plan. 

3. Within five (5) business days after receipt of the Construction Drawings and the Cost Estimate, Tenant shall either approve or
disapprove of the Construction Drawings and the Cost Estimate by written notice to Landlord. If Tenant disapproves of the Construction Drawings, Tenant shall specify in detail the changes or modifications to the Construction Drawings and the Cost
Estimate required by Tenant. Any such request for changes or modifications shall be subject to Landlord’s approval, provided, however, if Tenant desires changes, Landlord shall not unreasonably withhold its approval of such changes and the
parties shall confer and negotiate in good faith to reach agreement on modifications to the Construction Drawings and the Cost Estimate as a consequence of such change. If Landlord approves of Tenant’s proposed change or modification, Landlord
shall arrange for Landlord’s architect to revise the Construction Drawings and resubmit the Construction Drawings to Tenant for its review and approval in accordance with the procedure set forth above. Tenant acknowledges that the Construction
Drawings are subject to the approval of the appropriate government authorities. It shall be Tenant’s responsibility to ensure that the design and function of the 2nd Floor Tenant Improvements and 2nd Floor Tenant Extra Improvements are suitable
for Tenant’s business and needs. The improvements shall be constructed in a good and workmanlike manner in accordance with the approved plans and current building standards, laws, regulations, ordinances and codes. Landlord shall not be
required to install any 2nd Floor Tenant Improvements or 2nd Floor Tenant Extra Improvements which do not conform to the Construction Drawings. If the parties are unable to reach agreement on the Construction Drawings or Cost Estimate within fifteen
(15) days following delivery of the Construction Drawings and Cost Estimate to Tenant, Landlord, Tenant and General Contractor shall meet and discuss in good faith resolution of the cost and design issues until the issues are resolved.

  
 Exhibit B-2,
Page 1 

 4. Landlord shall furnish and install the 2nd Floor Tenant Improvements and 2nd Floor Tenant Extra Improvements as set forth on the Construction
Drawings. 
 (a) If the tenant improvements for the entire second floor are planned and completed all at
the same time, then Landlord shall pay for the cost of the 2nd Floor Tenant Improvements, including the costs of the plans and permits therefor. 
 (b) If the tenant improvements for the second floor are planned and completed in two or more phases, then Landlord shall pay for the cost of the 2nd Floor Tenant Improvements up to a maximum of $50 per
rentable square foot of the 2nd Floor Premises, for a total maximum amount (the “Landlord Allowance”) of $938,650 ($50.00 x 18,773 r.s.f.), subject to adjustment to reflect to the actual size of the 2nd Floor Premises following the
construction of the Building. All costs to furnish and install the 2nd Floor Tenant Improvements (including without limitation, actual, reasonable fees incurred by Landlord for construction management services (not to exceed 4% of all other hard and costs of the 2nd Floor Tenant Improvements), design, engineering, permit, and all
other soft costs) in excess of the Landlord Allowance shall be paid by Tenant within thirty (30) days following receipt of Landlord’s written demand therefor. If any portion of the Landlord Allowance is remaining after completion of the
2nd Floor Tenant Improvements, then Tenant may apply such
excess to the cost of the 2nd Floor Tenant Extra
Improvements. 
 All costs to furnish and install the 2nd Floor Tenant Extra Improvements (including without limitation,
actual, reasonable fees incurred by Landlord for construction management services (not to exceed 4% of all other hard and costs of the 2nd Floor Tenant Extra Improvements), design, engineering, permit, and all other soft costs) shall be paid by Tenant
within thirty (30) days following receipt of Landlord’s written demand therefor, which demand(s) may be submitted to Tenant prior to commencement of construction of the 2nd Floor Tenant Extra Improvements based on Landlord’s estimate
of such costs. If Tenant fails to pay within such 30-day period, Landlord may, in addition to all other available remedies, (i) delay the commencement of construction of the 2nd Floor Tenant Extra Improvements if such work has not commenced, or
(ii) stop construction of the 2nd Floor Tenant Extra Improvements if such work has commenced, in either case until such time as Tenant pays such amounts. Tenant shall have no obligation to restore the 2nd Floor Tenant Improvements or 2nd Floor Tenant Extra Improvements. 

5. In no event shall the 2nd Floor Tenant Improvements payable by Landlord include (i) the costs of procuring
or installing any trade fixtures, equipment, furniture, furnishings, telephone or computer equipment or wiring or other personal property (“Personal Property”) or (ii) any Change Orders (as the term is defined in Paragraph 6 below)
requested by Tenant or related to 2nd Floor Tenant Extra
Improvements, which increase the cost of the 2nd Floor
Tenant Improvements. Such items shall be paid by Tenant. 
 6. After the Construction Drawings have been approved by Landlord
and Tenant as provided above, neither party shall have the right to require extra work or changes to the work provided that neither party will unreasonably withhold its consent to changes required by the City of Petaluma or any other governmental
body with jurisdiction. However, following Tenant’s approval of the Construction Drawings, Tenant may request changes or modifications thereto (“Change Order”), however, the cost of any Change Order(s) which increase the total
construction costs shall be borne by Tenant in the amount set forth in the approved Change Order. If Tenant shall request any Change Order, then Landlord shall promptly give Tenant a written estimate of (a) the cost of engineering and design
services to prepare the Change Order, (b) the cost of work to be performed pursuant to the Change Order, and (c) the time delay in substantial completion of the Premises expected because of such requested Change Order. Within three
(3) days after Tenant’s receipt of the written estimate, Tenant shall notify Landlord in writing whether it approves the written estimate. Within thirty (30) days after Landlord’s submission to Tenant of any invoice for costs
incurred in connection with such Change Order, Tenant shall pay the same to Landlord if such Change Order increases the cost of construction. If such written authorization is not received by Landlord, then Landlord shall not be obligated to commence
work on the 2nd Floor Premises and Tenant shall be responsible for any delay in the completion of the 2nd Floor Premises in accordance with Paragraph 7 below. 

  
 Exhibit B-2,
Page 2 

 7. If the 2nd Floor Rent Commencement has not occurred on or before the 2nd Floor Target Date, and if the cause of the delay in the occurrence of the 2nd Floor Rent Commencement is attributable to Tenant, then the 2nd Floor Rent Commencement shall be on the date the 2nd Floor Rent Commencement otherwise would have occurred but for the
Tenant delays (“Tenant Delays”). Tenant Delays shall mean delays in substantial completion of the improvements beyond the 2nd Floor Target Date caused by (a) Tenant’s failure to approve the Construction Drawings within the time period
noted above, (b) Tenant’s request for special materials not available when needed for construction in accordance with the construction schedule, (c) Change Orders, (d) Tenant’s or Tenant’s agents’ interference with
Landlord’s work (provided that there shall be a grace period for the first two (2) days of interference, which shall not constitute Tenant Delays), and (e) Tenant’s failure to pay for 2nd Floor Tenant Improvements and 2nd Floor Tenant Extra Improvements within the time period noted above.
To the extent practicable, Landlord shall promptly notify Tenant of any interference with Landlord’s work by Tenant or Tenant’s agent. 
 8. Tenant may, with Landlord’s written consent, enter the 2nd Floor Premises subsequent to the Warm Shell Completion Date but prior to delivery of the 2nd Floor Premises to Tenant solely for the purpose of installing its
Personal Property, cabling, and telecommunications equipment in the 2nd Floor Premises as long as such entry will not interfere with the orderly construction and completion of the 2nd Floor Premises (hereinafter, “Tenant’s Work”).
Such entry shall be subject to all of the terms of the Lease except the obligation to pay Rent. Tenant shall notify Landlord of its desired time(s) of entry and shall submit for Landlord’s written approval the scope of the Tenant’s Work to
be performed and the name(s) of the contractor(s) who will perform such work. Tenant agrees to indemnify, defend and hold harmless Landlord and any mortgagee, ground lessor or beneficiary of a deed of trust encumbering, secured by or affecting the
2nd Floor Premises or the Building, from and against any and all claims, actions, losses, liabilities, damages, costs or expenses (including, without limitation, reasonable attorneys’ fees and claims for worker’s compensation) of any
nature whatsoever, arising out of or in connection with the Tenant’s Work (including, without limitation, claims for breach of warranty, personal injury or property damage) except to the extent due to the negligence, willful misconduct or
violation of this Lease by Landlord. 
 9. During the course of installation of Tenant’s Work, at Tenant’s expense,
Tenant shall obtain or maintain public liability and worker’s compensation insurance, in amounts acceptable to Landlord, and which name Landlord and Tenant as parties insured from and against any and all liability for death of or injury to
person or damage to property caused in or about or by reason of the construction of the Tenant’s Work. 
 10. Landlord
shall not be liable for any latent or patent defects therein, except that Landlord warrants the 2nd Floor Premises against defects and violations of law with respect to the original construction of the 2nd Floor Tenant Improvements for a period of
two (2) years from the date of substantial completion (the “Warranty Period”). 
 11. The 2nd Floor Premises
shall be deemed “substantially completed” as of the date that all of the following conditions are satisfied: 
 (a) The 2nd Floor Tenant Improvements and 2nd Floor Tenant Extra Improvements have been substantially completed in accordance with the approved Construction Drawings (except for those punch list items referenced in Paragraph 12 below), such that
Tenant can reasonably conduct business within the 2nd Floor Premises; 
 (b) A certificate of occupancy and/or finalized
building permit has been issued for the 2nd Floor Premises; and 
 (c) All building facilities and systems,
including electrical, plumbing and mechanical, serving the 2nd Floor Premises shall be in good operating order. 
 12.
Tenant’s acceptance of the 2nd Floor Premises shall
not be deemed a waiver of Tenant’s right to have defects in the 2nd Floor Premises repaired at no cost to Tenant during the Warranty Period. Tenant shall inspect the 2nd Floor Premises immediately prior to occupancy and compile and furnish Landlord with a punch list of
any missing or deficient 2nd Floor Tenant Improvements or
2nd Floor Tenant Extra Improvements. Landlord shall
complete the corrective 

  
 Exhibit B-2,
Page 3 

 
work noted in the punch list in a prompt, good and workman-like manner. Punch list corrections shall not delay the Commencement Date, nor shall a delay in making corrections be grounds for a
delay or reduction in any rent payments due Landlord. Tenant shall also give notice to Landlord whenever any such defect becomes reasonably apparent during the Warranty Period, and Landlord shall repair such defect as soon as practicable.

 13. All floor area calculations are from the center line of the partitions and the outside line of the exterior and hall
walls. No deduction is allowed for the columns, sprinkler risers, roof drains, or air conditioning units serving Tenant and located within the 2nd Floor Premises. 
 14. Landlord shall select the manufacturer and vendor of all building materials and equipment with respect to the 2nd Floor Tenant Improvements and 2nd Floor Tenant Extra Improvements to be constructed
hereunder. 
 15. Notwithstanding anything to the contrary contained in the Lease or this Work Letter. Tenant acknowledges and
agrees that the 2nd Floor Premises are intended for use by Tenant and the specification and design requirements for the 2nd Floor Tenant Improvements are not within the special knowledge or experience of Landlord. 

16. Tenant shall not mortgage, grant a security interest in or otherwise encumber all or any portion of the 2nd Floor Tenant
Improvements. 
 17. Notwithstanding anything in this Lease or Addendum to the contrary, the cost of the
2nd Floor Tenant Extra Improvements shall not include (and
Landlord shall be solely responsible for) the following: (a) costs to bring the Project into compliance with applicable laws and restrictions; (b) wages, labor and overhead for overtime and premium time; and (c) management or
supervision fees by Landlord other than actual, reasonable fees for construction management services (not to exceed 4% of all other hard and soft costs of the 2nd Floor Tenant Improvement and 2nd Floor Tenant Extra Improvements). 
 [SIGNATURES TO APPEAR ON FOLLOWING PAGE] 

  
 Exhibit B-2,
Page 4 

															
	“Landlord”	 		 	“Tenant”
			
	 REDWOOD BUSINESS CENTER 1 LLC,
 a California limited liability company
	 		 	 CYAN, INC.,

a Delaware corporation doing business as Cyan California

						
	By:	 	 Redwood Technology Center, LLC
 a California limited liability company
	 		 		 		 	
		 	Its:	 	Manager and Sole Member	 		 	By:	 	 /s/ Michael Zellner

		 		 		 		 		 		 	Name:	 	Michael Zellner
		 	By:	 	 G&W Ventures, LLC
 a California limited liability company
	 		 		 	Its:	 	CFO
		 		 	Its:	 	Manager	 		 		 		 	
		 		 		 		 	By:	 	  

		 		 		 		 		 	Name:	 	  

		 	By:	 	  /s/ Matthew T. White
	 		 		 	Its:	 	  

		 		 	Matthew T. White, Manager	 		 		 		 	
					
	 AMERIVINE TOWN CENTER, LLC,
 a California limited liability company
	 		 		 		 	
					
	By:  Amerivine Inc.,	 		 		 		 	
	a California corporation	 		 		 		 	
	Its: Sole Member	 		 		 		 	
						
	By:	 	 /s/ David F. Coleman
	 		 		 		 	
		 	David F. Coleman	 		 		 		 	
	Its:  President	 		 		 		 	

  
 Exhibit B-2,
Page 5 

 EXHIBIT C 

COMMENCEMENT DATE MEMORANDUM 
 With respect to that certain lease (“Lease”) dated             ,
            , between
                                         
                               , a
                                    (“Tenant”), and
                                        , a
                            (“Landlord”), pursuant to which Landlord leased to Tenant and Tenant
leased from Landlord approximately                             rentable square feet of space
(“Premises”) in the building located at
                                         
       , Tenant hereby acknowledges and certifies to Landlord as follows: 
  

	 	(1)	The Commencement Date is             and the Expiration Date is
            ; 

  

	 	(2)	The Premises contain                 rentable square feet of space; and

  

	 	(3)	Tenant has accepted and is currently in possession of the Premises and the Premises are acceptable for Tenant’s use. 

IN WITNESS WHEREOF, this Commencement Date Memorandum is executed this
                    day of                 ,
20    . 
  

			
	 “Tenant”

	
	
                        
                                         
                           ,

	
a                        
                                         
                         

		
	 By:
	 	  

	 Name:
	 	  

	 Its:
	 	  

  
 Exhibit C,
Page 1 

 EXHIBIT D 

RULES AND REGULATIONS 

It is further agreed that the following rules and regulations (these “Rules and Regulations”) shall be and are hereby made a part of this
Lease, and Tenant agrees that Tenant’s employees and agents, or any others permitted by Tenant to occupy or enter the Premises, will at all times abide by these Rules and Regulations, unless otherwise specified or provided for in the Lease, to
wit: 
 1. The driveways, entrances and exits to the Project, sidewalks, passages, building entries, lobbies, corridors, stairways, and
elevators of the Building shall not be obstructed by Tenant, or Tenant’s agents or employees, or used for any purpose other than ingress and egress to and from the Premises. Tenant or Tenant’s agents or employees shall not loiter on the
lawn areas or other common areas of the Project. 
 (a) Furniture, freight equipment and supplies will be moved in or out of the
Building only through the rear service entrances or other entrances designated by Landlord and then only during such hours and in such manner as may be reasonably prescribed by Landlord. Tenant shall cause its movers to use only the loading
facilities and entrances designated by Landlord. In the event Tenant’s movers damage any part of the Building or Project, Tenant shall pay to Landlord the amount required to repair said damage upon Landlord’s written request. 

(b) No safe or article, the weight of which may in the opinion of Landlord constitute a hazard to or damage to the Building or the
Building’s equipment, shall be moved into the Premises without Landlord’s prior written approval, but such consent or approval shall not be unreasonably withheld, conditioned or delayed. Landlord and Tenant shall mutually agree to the
location of such articles in the Premises. All damage done to the Project, Building or Premises by putting in, taking out or maintaining extra heavy equipment shall be repaired at the expense of Tenant. 

(c) Landlord reserves the right to close and keep locked any and all entrances and exits of the Building and Project and gates or doors
closing the parking areas thereof during such hours as Landlord may deem advisable for the adequate protection of the Project and all tenants therein; provided, Tenant shall have reasonable access to the Premises at all times except in the event of
an emergency requiring the temporary closure of the Building. 
 2. Except as otherwise provided for in the Lease, no sign, advertisement or
notice shall be inscribed, painted or affixed on any part of the inside or outside of the Building unless of such color, size and style and in such place upon or in the Building as shall be first approved in writing by Landlord. No furniture or
other materials shall be placed in front of the Building or in any lobby or corridor without the prior written consent of Landlord. Landlord shall have the right to remove all non permitted signs and furniture without notice to Tenant. 

3. Tenant shall not employ any person or persons other than the janitor or cleaning contractor of Landlord for the purpose of cleaning or taking care of
the Premises without the prior written consent of Landlord, which consent shall not be unreasonably withheld, conditioned or delayed. Except as otherwise provided in the Lease, Landlord shall in no way be responsible to Tenant for any loss of
property from the Premises, however occurring. The janitor of the Building may at all times keep a pass key, and other agents of Landlord shall at all times be allowed admittance to the Premises in accordance with the provisions set forth in the
Lease. 
 4. Water closets and other water fixtures shall not be used for any purpose other than that for which the same are intended, and any
damage resulting to the same from misuse on the part of Tenant or Tenant’s agents or employees, shall be paid for by Tenant. No person shall waste water by tying back or wedging the faucets or in any other manner. 

5. No animals except seeing-eye dogs or other animals necessary to the functioning of handicapped personnel shall be allowed on the lawns or sidewalks or
in the offices, halls, and corridors of the Building. 
 6. No persons shall disturb the occupants of this or adjoining buildings or premises by
the use of any radio, sound equipment or musical instrument or by the making of loud or improper 

  
 Exhibit D,
Page 2 

 
noises, nor interfere in any way with the other tenants or those having business with them. Should sound mitigation measures be required due to sounds originating in the Premises, the costs of
such measures shall be paid for by Tenant. 
 7. Bicycles or other vehicles, other than wheel chairs, shall not be permitted in the offices,
halls, corridors and lobbies in the Building nor shall any obstruction of sidewalks or entrances of the Building by such be permitted. 
 8.
Tenant shall not allow anything to be placed on the outside of the Building, nor shall anything be thrown by Tenant or Tenant’s agents or employees, out of the windows or doors, or down the corridors, ventilation ducts or shafts of the
Building. Tenant, except in case of fire or other emergency, shall not open any outside window. 
 9. No awnings shall be placed over any window
or entrance. 
 10. All garbage, including wet garbage, refuse or trash shall be placed by Tenant in the receptacles designated by Landlord for
that purpose. Tenant shall not burn any trash or garbage at any time in or about the leased Premises or any area of the Project. Tenant and Tenant’s officers, agents, and employees shall not throw cigar or cigarette butts or other substances or
litter of any kind in or about the Project. 
 11. Tenant shall not install or operate any steam or gas engine or boiler, or other machinery or
carry on any mechanical business, other than such mechanical business which normally is identified with general use in the Premises. Explosives or other articles of an extra hazardous nature shall not be brought into the Building complex.

 12. Any painting or decorating as may be agreed to be done by and at the expense of Landlord shall be done during regular weekday working
hours. Should Tenant desire such work on Saturdays, Sundays, holidays or outside of regular working hours, Tenant shall pay for the extra cost thereof, if any. 
 13. Tenant and Tenant’s agents and employees shall park their vehicles in areas designated from time-to-time for
employee parking. 
 14. Tenant shall not mark, drive nails, screw, bore, or drill into, paint or in any way deface the common area walls,
exterior walls, roof, foundations, bearing walls, or pillars without the prior written consent of Landlord. The expense of repairing any breakage, stoppage or damage resulting from a violation of this rule shall be borne by Tenant. 

15. No waiver of any rule or regulation by Landlord shall be effective unless expressed in writing and signed by Landlord or his authorized agent.

 16. Tenant shall be responsible for cleaning up any trash blowing around their facility that may have been left by their customers or
employees. 
 17. In the event of any conflict between these Rules and Regulations or any further or modified rules and regulations from time to
time issued by Landlord, and the Lease provisions, the Lease provisions shall govern and control. 
 18. Landlord reserves the right at any time
to change or rescind any one or more of these Rules and Regulations, or to make such other and further reasonable rules and regulations as in Landlord’s judgment may from time to time be necessary for the management, safety, care and
cleanliness of the Premises, and for the preservation of good order therein, as well as for the convenience of other tenants of the Project. Landlord shall not be responsible to Tenant or to any other person for the non-observance or violation of
these Rules and Regulations by any other tenant or person. Tenant shall be deemed to have read these rules and Regulations and to have agreed to abide by them as a condition to its occupancy of the space herein leased, and Tenant shall abide by any
additional rules and regulations which are ordered or requested by Landlord or by any governmental authority. 

  
 Exhibit D,
Page 3EX-10.5

 Exhibit 10.5 
 FIRST AMENDMENT TO LEASE 
 THIS FIRST AMENDMENT TO LEASE (this
“Amendment”) dated as of July 29, 2013 is entered into between REDWOOD BUSINESS CENTER 1 LLC, a California limited liability company and AMERIVINE TOWN CENTER, LLC, a California limited liability company (collectively,
“Landlord”), and CYAN, INC., WHICH WILL DO BUSINESS IN CALIFORNIA AS CYAN CALIFORNIA, a Delaware corporation (“Tenant”). 
 THE PARTIES ENTER INTO THIS AMENDMENT based upon the following facts, understandings and intentions: 
 A. Landlord and Tenant previously entered into that certain Redwood Business Center Full Service Lease dated as of July 2, 2013 (the “Lease”), pursuant to which Landlord leases to Tenant
approximately Thirty Eight Thousand Seven Hundred Seventy Eight (37,778) rentable square feet of space within the building to built and located at 1385 North McDowell Boulevard in Redwood Business Center, Petaluma, California (the
“Building”), as more particularly described in the Lease. The capitalized terms used in this Amendment and not otherwise defined herein shall have the same meanings given to such terms in the Lease. 

B. Landlord and Tenant now desire to amend the Lease as provided herein. 

NOW, THEREFORE, IN CONSIDERATION of the mutual covenants and promises of the parties, the receipt and adequacy of which are hereby
acknowledged, the parties hereto agree as follows: 
 1. Condition Precedent—Financing. The expiration date
for the condition precedent set forth in Section 26 of the Lease is hereby extended from July 31, 2013 to August 14, 2013. 
 2. Entire Agreement. This Amendment, together with the Lease, represents the entire understanding between Landlord and Tenant concerning the subject matter hereof, and there are no
understandings or agreements between them relating to the Lease, the Current Premises or Suite 350 not set forth in writing and signed by the parties hereto. No party hereto has relied upon any representation, warranty or understanding not set forth
herein, either oral or written, as an inducement to enter into this Amendment. 
 3. Continuing Obligations.
Except as expressly set forth to the contrary in this Amendment, the Lease remains unmodified and in full force and effect. To the extent of any conflict between the terms of this Amendment and the terms of the Lease, the terms of this Amendment
shall control. 

 4. Counterparts/Facsimile. This Amendment may be executed in
counterparts and delivered via facsimile. 
 [SIGNATURES ON FOLLOWING PAGE] 

 IN WITNESS WHEREOF, the parties hereto have executed this Amendment as of the
day and year first above written. 
  

											
	 REDWOOD BUSINESS CENTER 1 LLC,
 a California limited liability company
	 	CYAN, INC., WHICH WILL DO BUSINESS IN CALIFORNIA AS CYAN CALIFORNIA, a Delaware corporation
				
	By:	 	 Redwood Technology Center, LLC
 a California limited liability company
	 		 	
		 	Its:	 	Manager and Sole Member	 	By:	 	 /s/ Michael Zellner

		 		 		 		 	Name:	 	Michael Zellner
		 	By:	 	 G&W Ventures, LLC
 a California limited liability company
	 	Its:	 	CFO
		 		 	Its:	 	Manager	 		 	
						
		 		 	By:	 	 /s/ Matthew T. White
	 		 	
		 		 		 	Matthew T. White, Manager	 		 	
			
	 AMERIVINE TOWN CENTER, LLC,
 a California limited liability company
	 		 	
				
	By:	 	 Amerivine Inc.
 a
California corporation
	 		 	
		 	Its:	 	Sole Member	 		 	
					
		 	By:	 	 /s/ David F. Coleman
	 		 	
		 		 	David F. Coleman	 		 	
		 		 	Its: President

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00220-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00220-of-00352.parquet"}]]