Document:

Exhibit
10.18

 

Construction
project strategic cooperation agreement

 

Party
A: Dongyuan Mingyuan Garden Investment Co., Ltd.

 

Party
B: Hunan Shuncheng Road and Bridge Construction Co., Ltd.

 

In
response to the country’s call for the revitalization of the country, regarding the strategic cooperation of the Beacon Basin
(Shuntian) rural complex construction project, after repeated consultations, the two parties reached a consensus on cooperation
and decided to follow the principles of fairness, justice, and mutual benefit, and hereby sign Ming Yuan- The strategic cooperation
agreement of the rural farm construction project is as follows:

 

Article
1 Basic Information of Party A Project

 

Party
A, as the lighthouse basin (Shuntian) rural complex project company, is responsible for the entire lighthouse basin rural
complex Development, operation and management of large-scale projects. The Dengta Basin (Shuntian) rural complex project is
located in Shuntian, Dongyuan County-Town, with a total area of ​​114.28 square kilometers, and a core urban area
of ​​about 24,535 acres. “Sea town, rural e-town, art resort”, build China with “Internet of
Things + Finance + Rural Complex” business model Characteristic small cities: build modern Heyuan sub-central city, IoT
town, art town, sports town, and modern agricultural forest. Industry, small towns, health care and pensions, biotechnology,
eco-themed tourism, etc. The entire project was started in March 2018 with the great attention and strong support of leaders
from the state, provinces, cities, and counties.5, and has already achieved initial results.

 

Article
2 Basic Information of Party B Company

 

Party
B, as a construction company of Hunan Shuncheng Road and Bridge Construction Co., Ltd., has three national qualifications for
national highway engineering general contracting. Its business scope includes road, bridge engineering, municipal public works,
housing construction engineering, garden greening engineering design and construction, and has high quality construction projects
The technical management team and the outstanding construction team are all guaranteed to reach high-quality construction projects.

 

     

     

    

 

Article
3 Contents and Methods of Cooperation

 

1、
The cooperation content is about 3,600 meters of reconstruction of municipal roads in the core section of provincial highway s341,
or construction of 2,200 meters of new municipal roads (two-way, six lanes). The project is open for bidding. Party A provides
the design. According to Heyuan municipal municipal fixed fee collection and settlement, according to the actual project volume
review, the county financial appropriation part shall pay the party B in accordance with regular procedures. For the project volume
exceeding the fiscal budget, Party A shall be responsible for paying the project fund according to the above accounting method.

 

2、
The amount of cooperation between the two parties is about 60 million yuan. If Party B can complete the construction of the
contract project with quality and quantity, Party A promises to continue to provide Party B with various construction
projects in the future, and the agreement will be signed separately.

 

 

 

    2

     

    

 

3、
The valuation principle implements the quota standard: the implementation of other relevant quotas such as the
“Measures for the Valuation of Municipal Engineering in Guangdong Province” and other relevant quotas, such as
Heyuan City, which has the latest information price, is subject to Heyuan City’s information. The calculation will be
performed in accordance with the “cost information” of the municipal construction cost of Guangzhou in the same
period.

 

4、
The amount paid by Party A shall issue a true and valid invoice to Party A.

 

5、
For the above projects, Party B signed a construction contract after winning the bid, and Party A helped Party B to apply for
30% of the advance payment of the project.

 

Article
4 Party A’s duties, rights and obligations

 

1、
Ensure the legality and authenticity of the construction project provided;

 

2、
Provide relevant construction projects to Party B for construction according to the agreement; -

 

3、
Do a good job of coordinating the relationship between relevant functional departments of counties and towns to ensure the smooth
progress of Party B’s construction and construction;

 

4、
Provide the first construction project construction drawing within 3 working days after signing the agreement, and ensure that
the working face is delivered for Party B’s construction within two months.

 

Article
5 Duties, Rights and Obligations of Party B

 

1、
Register the branch company in Dongyuan County after the agreement is signed;

 

2、
After signing the agreement, organize a high-level building construction team to enter the site;

 

    3

     

    

 

3、
Ensure construction technology, management, and funding guarantees, and complete the project construction in accordance with the
contract;

 

4、
Register the branch company in the project site, pay the tax due in time according to the requirements of the local government,
and do not owe migrant workers Salary, maintaining the image of the project.

 

Article
6 Confidentiality Provisions

 

Both
parties A and B have a confidentiality obligation for the development and construction of the Dengta Basin Rural Complex project.
Without the other party’s consent, the project information must not be disclosed to any party that may form a business competition.

 

Article
7 Amendment, Alteration and Termination of Agreement

 

1、
Changes to this agreement must be signed by Party A and Party B in order to take effect;

 

2、
Due to force majeure, this agreement cannot be performed, and the parties can agree to postpone the implementation or terminate
the cooperation, and this agreement can also be terminated in advance.

 

Article
8 Liability for breach of contract

 

1.After
the agreement is signed, both parties A and B shall execute it consciously and shall not breach the contract.

 

All
losses caused by this.

 

    4

     

    

 

2.
If Party B’s construction quality is poor, delaying the construction period, or management confusion affects the quality and
construction period, Party A has the right to terminate the cooperation.

 

Article
9 Settlement of Disputes

 

All
disputes between the two parties due to the implementation of the agreement or related to this agreement shall be settled in accordance
with the principle of friendly negotiation. .

 

Article
10 Agreement comes into effect

 

1.This
agreement takes effect after it is formally signed by both parties and completed the purchase of the house.

 

2.After
this agreement is signed by each party, it is a legally valid document.The two parties must strictly abide by it.

 

One
party may not terminate without authorization;

 

4.  
This agreement is made in two copies, each holding one copy, which has the same legal effect.

 

 

 

 

 

 5Exhibit
10.19

 

Lump-sum
Agency Agreement of Tianluncheng Project

 

Entrusting
Party: Shenzhen Mingyuan Investment Holding Co., Ltd. (hereinafter referred to as “Party A”) 

 

Entrusted
Party: Shenzhen Jiana Technology Co., Ltd. Heyuan Branch (hereinafter referred to as “Party B”)

 

In
order to rapidly promote the construction of Lighthouse Basin Rural Complex of Shuntian Town, Dongyuan County, Heyuan, fully utilize
the advantages of the ecological environment, tourism resources and traffic location, etc of Shuntian, and create the national
characteristic rural complex town, and through repeated market survey, Party A and Party B have reached consensus through friendly
negotiation in respect of the location and construction of Mingyuan Tianlun Rural Complex (hereinafter referred to as “Tianluncheng”)
project of Shuntian Town; now therefore, the Parties have hereby entered into the following terms and conditions in respect of
entrusting the operation of the Project to Party B:

 

Article
I Project Land Profile: “Tianluncheng” project is located at the interior of Lighthouse Basin Rural Complex, Daping
Village, Shuntian Town, Dongyuan County, Heyuan. Phase I of the project occupies the land of 1678.22 mu; thereinto construction
land 605.41 mu, ancient tree park land 66.5 mu, ecological farm 385.58 mu, finance manor 255.56 mu, and other supporting land
365.17 mu. The total building area of the project is 423600m2, thereinto: dwelling for the aged 340000m2 (about 3300
households). Supporting facilities for the aged 20000m2 (medical, catering, bank, supermarket, health examination, longevity
and healthcare, college for senior citizens, club for senior citizens, tourism, stadium, undertaking department for senior citizens,
property management, etc), resettlement community 16000 m2, finance manor 7600m2, business street 40000 m2.
The land of phase II is about 800 mu, used to building Daping socialism new village, finance manor, etc.

 

Article
II Entrusted Cooperation Method 

 

1.
Party A shall provide lawful and good quality land resources and handle land procedures (including but not limited to land expropriation,
land scale, land index, forest declaration, etc, and land listing, and handling state-owned land certificate, construction land
planning permit, construction planning permit, construction permit, etc). Party A shall assume all land, project application
expenses; Party B shall pay fixed land costs to Party A at the price of 500 Yuan/m2 according to the building area that
has been actually sold;

 

2.
As entrusted by Party A, Party B shall be responsible for full-process planning, promotion and publicity, building sales, operation
management, etc, and shall assume all expenses as incurred during the operation process;

 

     

     

    

 

3.
Party B shall introduce “EPC” general contractor, take charge of project exploration, design, purchase, engineering
construction, construction management, completion acceptance, etc, assume all expenses of the project construction by lump-sum
way, and charge construction expenses according to the quote standards as implemented under the equal conditions of Heyuan. The
construction expenses of EPC general contractor shall be paid by Party A;

 

4.
Party B shall be entrusted by Party A to operate the project by lump-sum, and determine the selling prices of the building in
Party B’s sole discretion. Party B shall according to the building area that is actually sold, pay fixed lump-sum price
at [650] Yuan/m2 (including but not limited to exploration, architecture scheme design, construction drawing design, drawing
review, planning and architecture construction declaration, detection, acceptance, etc), and shall pay land costs recycling fee
and EPC general contractor construction costs to Party A. After having paid fixed lump-sum price, land costs recycling fee and
EPC general contractor construction costs, the remaining profit shall be owned by Party B. 

 

5.
Party B shall conduct promotion and publicity through Fangrong Zaixian Platform, organize the sales of Yikatong members and offline
store resources and charge building purchase prices online. Party B shall settle with Party A once at the end of each month after
the sales starts. Party B shall according to the area that is actually sold, pay “fixed lump-sum price [650] Yuan/m2+
land costs recycling fee [500] Yuan/m2+EPC general contractor construction costs[ ] Yuan/m2(subject to the quote price
of actual settlement)” to Party A; after the building has sold over 85%, the Parties shall organize the liquidation of the
building; 

 

6.
As the project development subject, Party A shall cooperate with Party B in completing the signing of Commodity House Sales
and Purchase Contract, building mortgage loan, signing of the contract of payment by installments, handling real estate certificate,
and the handover procedures of property management, etc.

 

Article
III Charges, Payment and Taxes

 

1.
Party B collects land transfer and building sales amounts on behalf of Party A. Party B shall settle the lump-sum price of land
transfer of the first batch in a lump sum with Party A within half a year, and shall settle the building sales amounts with Party
A at the end of each month subsequently. Party A shall pay construction costs to EPC general contractor according to the project
progress or agreed payment nodes;

 

2.
Party B shall according to the area that is actually sold, pay “fixed lump-sum price [650] Yuan/m2+ land costs recycling
fee [500] Yuan/m2+EPC general contractor construction costs[ ] Yuan/m2(subject to the quote price of actual settlement)”
to Party A; the remaining will be all taken as the lump-sum operation return of Party B;

 

    2

     

    

 

3.
If the building has been sold over 85% or has been opened for 2 or more years, the portion that has not been sold will be deemed
as being purchased by Party B, and Party B shall pay up the remaining “fixed lump-sum price [650] Yuan/m2+ land costs
recycling fee [500] Yuan/m2+EPC general contractor construction costs[ ] Yuan/m2(subject to the quote price of actual
settlement)” in a lump sum;

 

4.
Party B shall pay “fixed lump-sum price [650] Yuan/m2+ land costs recycling fee [500] Yuan/m2+EPC general contractor
construction costs[ ] Yuan/m2(subject to the quote price of actual settlement)” as the building selling prices; Party
A shall issue invoices to owners, and the owners handle real estate certificate with such invoices. Party A shall pay business
tax (or VAT), land VAT, income tax, etc according to such amounts;

 

5.
Party B shall issue service invoice to owners according to the lump-sum operation expenses that have been actually charged, and
shall pay business tax (or VAT), income tax, etc by itself;

 

6.
The cooperation of Party A and Party B hereunder is only limited to the salable portion of land and building. All construction
costs (including land, architecture, decoration, etc) of the supporting operation rooms, management rooms and other property that
is owned by Party A shall be assumed by Party A.

 

Article
IV Party A’s Duties, Rights and Obligations

 

1.
Party A shall be responsible for land expropriation declaration, environmental review, forest declaration, removal, land use procedures,
land listing, land certificate, construction land planning permit, architecture planning permit, construction permit, pre-sale
certificate, real estate certificate, etc; 00000

 

2.
Party A shall assume all land and construction declaration expenses;

 

3.
Party A shall try its best to coordinate the relations among the relevant departments of county/town, villagers’ committee
and villagers, so as to ensure that the project will be constructed smoothly;

 

4.
Party A has the right to charge fixed lump-sum price from Party B, land costs recycling fee and EPC general contractor’s
construction fee.

 

Article
V Party B’s Duties, Rights and Obligations

 

1.
Party B shall set up a professional team to take charge of the full-process planning, promotion and publicity, building sales,
operation management, etc of the project, and shall assume corresponding expenses;

 

2.
Party B shall introduce EPC general contractor, take charge of full construction of the project and assume corresponding expenses;

 

3.
Party B shall provide Fangrong Zaixian Platform, organize building sales, complete sales tasks as scheduled and timely settle
the building sales amounts that shall be payable to Party A;

 

4.
Party B enjoys the full operation lump-sum price of sales revenue after paying Party A.

 

    3

     

    

 

Article
VI Effectiveness

 

1.
This Agreement shall become effective upon being signed and sealed by the Parties;

 

2.
The period of validity of this Agreement shall be from the date of signing to the date when the project has been completed.

 

Article
VII Liabilities for Breach

 

1.
After the effectiveness of this Agreement, the Parties shall fully, properly and timely perform their obligations hereunder according
to this Agreement and all appendixes hereto. Any breach of any provision of this Agreement by either party hereto shall constitute
a default. In case of any default of either party, the breaching party shall compensate for all losses as suffered by the non-breaching
party therefore, and the performance of this Agreement shall be continued;

 

2.
Party B must complete the operation of Tianluncheng Project according to the requirements of this Agreement within 3 years. If
the project fails to be completed within 3 years due to Party B’s cause, it shall constitute the default of Party B; if
the project fails to be completed within 3 years due to Party A’s cause, it shall constitute the default of Party A;

 

3.
Any failure or delay in exercising this Agreement or certain right in law shall not operate as the waiver of such right or other
right. Single or partial exercise of certain right under this Agreement or in law shall not prejudice the further exercise of
such right or other right.

 

Article
VIII Modification, Alteration and Dissolution of this Agreement

 

1.
Any modification or alteration of this Agreement shall be invalid, unless the Parties shall otherwise jointly sign a written agreement
through negotiation;

 

2.
This Agreement may be dissolved in case:

 

(1)
The Parties hereto dissolve this Agreement through negotiation;

 

(2)
If either party hereto breaches any provision of this Agreement and fails to correct such breach within 30 days after the receipt
of the written notice from the non-breaching party, or breaches any provision of this Agreement for two or more accumulative times,
the non-breaching party has the right to unilaterally dissolve this Agreement;

 

(3)
The performance of this Agreement cannot be continued due to force majeure.

 

Article
IX Dispute Resolution 

 

1.
The effectiveness, interpretation and performance of this Agreement shall be governed by the laws of the People’s Republic
of China;

 

2.
Any dispute arising between the Parties due to this Agreement shall be settled through friendly negotiation firstly; in case negotiation
fails, such dispute may be submitted to Shenzhen Court of International Arbitration for arbitration;

 

    4

     

    

 

3.
During the period when the arbitration proceeding under this Article is being conducted, this Agreement shall remain in full force
in all respects other than the matters involved in arbitration. Except the obligations as involved in arbitration, the Parties
shall continue performing and exercising their obligations and rights hereunder.

 

Article
X Miscellaneous 

 

1.
For any matter not covered herein, the Parties shall sign a supplementary agreement through negotiation; such supplementary agreement
and this Agreement shall be equally authentic;

 

2.
This Agreement is made in duplicate, one for each party hereto.

 

(There
is no text on this page. This page is the execution page to Lump-sum Agency Agreement of Tianluncheng Project)

 

Party
A: (Official Seal)

 

Address:
CDE, Floor 7, Tower A, Jinfeng Building, No. 1001, Shangbu South Road, Futian District, Shenzhen Municipality

Party
A’s Representative (Signature):

Telephone:

Date
of Signing: March 16, 2019

 

Party
B: (Official Seal)

 

Address:
In the Courtyard of the Government of Shuntian Town, Dongyuan County, Heyuan

Party
B’s Representative (Signature):

Telephone:

Date
of Signing: March 16, 2019

 

 5

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00303-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00303-of-00352.parquet"}]]