Document:

EX-10.1.42

 Exhibit 10.1.42 

THE USE OF THE FOLLOWING NOTATION IN THIS EXHIBIT INDICATES THAT THE CONFIDENTIAL PORTION HAS BEEN OMITTED PURSUANT TO A REQUEST FOR
CONFIDENTIAL TREATMENT AND THE OMITTED MATERIAL HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION: [***] 

Product Development and Manufacturing Agreement 
 XipLink XA/XE Airlink Systems 
 This PRODUCT DEVELOPMENT
AND MANUFACTURING AGREEMENT dated October 3, 2011 is between Gogo LLC, a Delaware limited liability, with a principal place of business located at 1250 N. Arlington Heights Road, Itasca, IL
60143, (“Gogo”) and XipLink, Inc, a Canadian Controlled Private Corporation based in the province of Quebec, with a principal place of business located at 3981 St. Laurent Blvd. Suite 800, Montreal, Quebec, Canada H2W 1Y5
(“XipLink”). 
 It is agreed as follows: 
  

	1.	Products and Services. Under the terms of this agreement, Gogo retains XipLink to provide the product XipLink XA-30K/Single Appliance Ground System Hardware Unit
(and its related operating system and client software collectively referred to as the “XA-30K/Single Appliance Unit”) to interconnect with Gogo’s next generation Air-to-Ground/4 Network (“ATG 4”), and to provide and
license XipLink’s XE embedded software product that shall be installed and functional on Gogo’s Airborne Server ATG5000 Processor Card (“XE-CM/B User Software”) located on aircraft. The utilization of these components in the Gogo
ATG 4 Network allows for enhanced transmissions to and from the aircraft modems. Such hardware and software components shall be collectively referred to in this Agreement as the “Product(s).” XipLink will provide the Products, according to
XipLink product specification and any modifications will be described in Exhibit A: XA/XE Airlink System Project Outline. In addition, XipLink will fabricate the Products(s), assemble the Product(s), supply and license the Product(s) to Gogo,
and provide product support as described herein. 

  

	2.	Product development and acceptance. XipLink will develop and deliver the deliverables described in Exhibit A according to the schedule described in
Exhibit A. Gogo will have up to four (4) business days to examine each deliverable and determine if it conforms to the applicable requirements. If the deliverable meets the requirements, Gogo will signify acceptance of the
deliverable. Gogo’s acceptance of any deliverable will not release XipLink from its warranty obligations under section 5. If the deliverable does not meet the requirements in Gogo’s opinion, Gogo will indicate rejection of the
deliverable, and provide a list of errors. Within ten (10) days of receiving a rejection, XipLink will correct such errors so that the deliverable conforms to the applicable requirements. Upon correction of the errors, XipLink will re-deliver
the corrected deliverable to Gogo, at XipLink’s expense, which corrected deliverable will be subject to the approval procedure described in this section. However, if errors still exist after three (3) attempts at correction by XipLink,
Gogo may terminate this agreement by providing notice to XipLink with Gogo’s description of the remaining errors. 

  

	3.	 Changes. After consultation with XipLink, Gogo may request changes to the work product at any time prior to final Product Acceptance, as defined
in Exhibit A (section 4: Statement of Work, “Final Documentation”). Requests for material changes (defined as any change that would materially increase the cost or time of the development cycle) will be submitted in writing.
XipLink is not required to accept material changes, but may do so based on mutually agreed terms (including any 

  
 1 

	 	
appropriate revisions to the milestone schedule). Upon acceptance by XipLink, Gogo and XipLink will sign the revised Exhibit A or specification. If XipLink does not accept the change within
ten (10) business days of Gogo’s request, Gogo may terminate this agreement by notice to XipLink. 

  

	4.	Manufacturing and support. XipLink will manufacture the Products, supply it to Gogo, and provide product support under the terms and conditions described in
Exhibit B: Supply and Support Terms. 

  

	5.	Warranty. The Product and any Product software will be free of defects in design, engineering and coding that interfere with product functionality or conformity
to the applicable product requirements. If any design, engineering or coding defect is documented within a period of [***] after Product Acceptance, XipLink will promptly provide any engineering analysis, redesign, coding and other services
necessary to analyze any failures and correct the defect. For any defect corrected under this warranty, XipLink will promptly provide revised documentation in accordance with the corresponding requirements of Exhibit A. The Products will
conform to and perform in accordance with the applicable specifications and will be free of defects in workmanship and materials for a period of one year after the date that Gogo resells the Product unit to the end user. Gogo’s sole remedy
in the event of XipLink’s sale of defective Product units will be, at XipLink’s option, the prompt replacement of the defective Product units or a refund of the purchase price paid by Gogo therefor. 

 

	    	XipLink warrants that any Product software does not and will not contain any disabling procedures (as defined in the next sentence), unless such procedure is used for
bug repair or product enhancement purposes (provided however, XipLink shall provide written notice to and obtain prior consent from Gogo before commencing any disabling procedures for the purpose of bug repair or product enhancement.)
“Disabling procedures” means any code or instructions that is capable of accessing, modifying, disabling, interfering with or otherwise harming the Product software, the Product, any connected system, or any information resident on such a
system, except in a manner that is intended for the functionality of the Product and fully disclosed in the documentation of the Product software. For example, “disabling procedures” includes any virus or other malicious code, software
lock, time bomb or trap door. Immediately upon discovery of any disabling procedures that may be included in the Product software, XipLink will notify Gogo, and will take any action necessary to identify and eradicate such disabling procedures, and
to carry out any recovery necessary to remedy the impacts of such disabling procedures, at XipLink’s expense. 

  

	    	EXCEPT FOR THE WARRANTIES PROVIDED IN THIS
AGREEMENT, ALL OTHER WARRANTIES, EXPRESS OR IMPLIED, INCLUDING THE IMPLIED WARRANTIES
OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE, ARE HEREBY EXCLUDED,
EXCEPT ANY WARRANTIES THAT CANNOT BY LAW BE EXCLUDED. 

 

	6.	Price and payment. Gogo will pay XipLink the engineering fees, in accordance with the milestone schedule, described in Exhibit A. Gogo will pay for Product
and software licensing at the production unit prices described in Exhibit B. Payments will be due net 45 days from invoice date, unless otherwise noted in the Exhibits or Purchase Orders. All payments shall be made in US Dollars.

  

	7.	Ownership. This section describes the ownership of the work product developed pursuant to this agreement, and all intellectual property rights related thereto,
including copyrights, trademarks, trade secrets, patents, moral rights, contract and licensing rights, and rights to enforce all of the foregoing (“Proprietary Rights”). 

 

	 	7.1	 “Technology” means any and all technical information (including ideas, techniques, designs, inventions, know-how, processes,
algorithms and specifications). “Gogo Technology” means the Technology provided by Gogo to XipLink pursuant to this agreement. “XipLink Technology” means the Technology that was in XipLink’s possession prior to receipt of
any Gogo Technology under this agreement, and that XipLink uses in performing its services 

  
 2 

	 	
under this agreement. “Project Technology” means the Technology that is conceived, made, reduced to practice, or learned by XipLink, or jointly, in the course of work performed under
this agreement. The Project Technology does not include the XipLink Technology or the Gogo Technology. 

  

	 	7.2	Gogo warrants that it owns, or has the right to use in accordance with this agreement, all Gogo Technology. XipLink warrants that it owns, or has the right to use in
accordance with this agreement, all XipLink Technology (including the right to grant the license described in the next section with respect to any XipLink Technology that is owned by a third party). 

 

	 	7.3	The Project Technology will be the exclusive property of XipLink, subject to Gogo’s rights set forth in Section 7.5. XipLink will promptly disclose to Gogo in
writing all Project Technology. 

  

	 	7.4	The XipLink Technology is the exclusive property of XipLink. Gogo has no rights to use XipLink Technology except pursuant to the license granted in this Agreement.
XipLink owns all right, title, and interest in Technology developed by or for XipLink independent of this agreement (including improvements thereto). 

  

	 	7.5	Gogo shall have the worldwide, non-exclusive right to use or remarket the XE-CM/B Software that XipLink is developing as defined in Exhibit A to any commercial airline,
general aviation manufacturer or related third parties that supply or service such airlines or aviation manufacturers or related third parties that supply or service such airlines or aviation manufactures in the airline industry. The XE-CM/B
Software only includes software executing on the Airborne Server ATG5000 Processor Card. The duration and term for Gogo’s non-exclusive use or remarketing of the XE-CM/B Software is perpetual. Notwithstanding the above, Gogo has exclusive use
of the Link Bonding features in the XE software for a period of 18 months for all features from acceptance sign-off for cabin-based systems for all commercial airline, general aviation manufacturer or related third parties that supply
or service such airlines or aviation manufacturers or related third parties that supply or service such airlines or aviation manufactures in the airline industry. Violation of this exclusivity will result in return of the initial contract amount
paid to XipLink from Gogo as set forth in Exhibit A. 

  

	8.	Licenses. Each party grants to the other a limited license to use certain Technology as described in this section. 

 

	 	8.1	With respect to any XipLink Technology that is incorporated in or required in connection with the use of any Products or deliverable under this agreement, XipLink
hereby grants to Gogo a perpetual, non-exclusive, royalty-free, irrevocable, worldwide license, with full rights of assignment and sublicense, to use, perform, copy, display, reproduce, market, sell, and distribute such Technology as a component of
Gogo products by all means now known or later developed, to modify and derive new products from the Deliverables, and to manufacture or have manufactured the Deliverables and any new products derived from the Deliverables. Gogo shall have
non-exclusive rights to remarket the Products, including the XE-CM/B Software to any commercial airline, aviation manufacturer or related third parties that supply or service such commercial airlines or aviation manufacturers perpetually. This
license does not grant to Gogo any rights to sell XipLink Technology separate from Gogo products. Gogo shall not disassemble, decompile, reverse engineer or modify the binary objects of the XE-CM/B Software. Gogo shall only permit third parties to
use the Product in connection with their use of the ATG 4 services provided by Gogo to its customers, as expressly authorized under this Agreement. 

  

	 	8.2	 With respect to any Gogo Technology that is incorporated in or required in connection with the manufacture of the Product, during the term and
subject to the provisions of this 

  
 3 

	 	
agreement, Gogo grants to XipLink a royalty-free, worldwide, non-exclusive license, with full rights of assignment to permitted assignees of XipLink’s other rights under this agreement, to
use such Technology to manufacture or have manufactured the Product for Gogo. 

  

	9.	Noncompetition. (Reserved) 

  

	10.	Design Documentation and XE-CM/B Software Escrow. The parties will implement Design Documentation and Software escrow as described in this section.

  

	 	10.1	The parties will execute within 10 days after Product Acceptance an escrow agreement in substantially the form attached as Exhibit C (the “Escrow
Agreement”) with Escrow Associates. (or another escrow agreement on terms reasonably acceptable to both parties with a third party escrow agent in the U.S. reasonably acceptable to both parties). Within ten (10) business days following the
execution of the Escrow Agreement, XipLink will deposit into the escrow account the materials identified in Exhibit A (section 7: “Documentation Criteria”) as to be deposited in the Design Documentation and Software Escrow (the
initial “Deposit”). XipLink will deposit updates, replacements and duplicate Deposits as described in the Escrow Agreement. 

  

	 	10.2	The occurrence of any of the events described in the Escrow Agreement will trigger release of the Deposit held in escrow. 

 

	 	10.3	All fees for establishing the Escrow Agreement and maintaining Gogo, as a beneficiary thereof will be paid by Gogo. 

 

	    	If the Deposit is released to Gogo pursuant to the Escrow Agreement, Gogo will not become the owner of the Deposit, but Gogo will have a perpetual, non-exclusive,
royalty-free, irrevocable, worldwide license, with full rights of assignment and sublicense, to use, perform, copy, display, reproduce, market, sell, and distribute Technology based on the Deposit as a component of Gogo products by all means now
known or later developed, to modify and derive new products from the Deposit, and to manufacture or have manufactured products based on or derived from the Deposit. This license does not grant to Gogo any rights to sell XipLink Technology separate
from Gogo products. 

  

	11.	Confidentiality. The terms of this agreement are Confidential Information under the Mutual Nondisclosure Agreement dated January 26, 2009 between XipLink
and Gogo (the “NDA”). The NDA is incorporated herein and will continue to govern Confidential Information exchanged during the term of this agreement. If there is any conflict between the provisions of the NDA and this agreement, this
agreement will govern. Those provisions of the NDA that are stated to survive termination, will survive termination of this agreement. 

  

	12.	Intellectual property indemnity. XipLink indemnifies Gogo against all loss, liability or expense (including reasonable attorney and witness fees and expenses)
arising out of any claim brought by a third party that any Product infringes upon intellectual property rights owned or controlled by the third party. In the event a Product is held or is believed by XipLink to infringe, XipLink will have the
option, at its expense, to (a) modify the Product to be non-infringing, (b) obtain for Gogo the right to continue using and selling the Product, or (c) substitute a non-infringing product of equivalent form, fit, function, weight and
quality. The indemnity under this section is subject to the conditions that XipLink is notified of the claim and given the opportunity to control the defense and settlement. 

  
 4 

	13.	Termination. 

  

	 	13.1	This agreement will continue in effect for [***] from the date of Product Acceptance, and thereafter will automatically renew from year to year unless terminated
upon notice at least 90 days prior to the renewal date. Either party may terminate this agreement immediately upon notice to the other: 

  

	 	(a)	if the other party materially breaches any of its obligations under this agreement (including on-time delivery of any deliverable described in Exhibit A) and the
breach is not cured within 10 days after notice thereof; or 

  

	 	(b)	if the other party files insolvency proceedings, or files an answer not seeking dismissal of an insolvency proceeding, or is adjudged insolvent; if substantially all
assets of the other party are transferred to an assignee for the benefit of creditors, a receiver or a trustee; if the other party loses any governmental authorization necessary to fulfill its obligations under this agreement; or if the other party
ceases to carry on business. 

  

	 	13.2	Upon termination of this agreement for any reason, (a) XipLink will promptly deliver to Gogo all Gogo property in the possession of XipLink, and all work
accomplished by XipLink or in process, inventories, and documentation relating to the Project Technology and (b) Gogo will promptly make payment to XipLink for amounts that are due to XipLink. If this agreement is terminated due to
XipLink’s default or failure to provide acceptable deliverables, Gogo will pay for all milestones completed by XipLink. If this agreement is terminated due to Gogo’s default, Gogo will also pay for the reasonable costs of all work in
process at the time of termination (provided that costs of development work will not exceed the contract fee specified in Exhibit A section 8). Termination of this agreement will not be exclusive of any other remedy available under this
agreement or applicable law. 

  

	 	13.3	The parties have considered the investment required to perform this agreement and possible losses in the event of termination, and agree that the rights of
termination provided in this agreement are absolute. IN NO EVENT WILL EITHER PARTY BE LIABLE TO THE
OTHER FOR DAMAGES ARISING FROM TERMINATION OF THIS AGREEMENT (WHETHER BASED
ON LOSS OF INVESTMENT, GOOD WILL, PROSPECTIVE PROFITS OR OTHERWISE). The preceding sentence does
not limit either party’s liability for breach of this agreement. 

  

	14.	General. 

  

	 	14.1	The parties are independent contractors. Neither party is an agent or partner of the other. Neither party has the right to incur any obligation on behalf of the
other. XipLink will provide its own equipment, tools (including software development tools and design tools) and other materials, except as specifically described in Exhibit A. If any tools or equipment are provided by Gogo, or are manufactured
or acquired for Gogo by XipLink at additional cost, such tools or equipment will remain the exclusive property of Gogo. XipLink waives any lien on such tools and equipment, and will return them to Gogo upon request in the same condition as received
by XipLink (ordinary wear excepted), regardless of any payments that may then be due from Gogo to XipLink. XipLink may subcontract its performance under this agreement to third parties without the prior written consent of Gogo. XipLink is
responsible for qualification and quality control of subcontractors, and for all actions of subcontractors relating to this agreement. XipLink will enter into agreements with any subcontractors (including contract manufacturers) requiring them to
assign to XipLink ownership of their work product and all Proprietary Rights therein, and to comply with nondisclosure terms at least as restrictive as those of the NDA. XipLink will provide Gogo with signed copies of its agreements with
subcontractors described in the preceding sentence. XipLink, at its expense, will maintain commercial general liability insurance having limits consistent with industry standards. 

  
 5 

	 	14.2	Both parties will comply with all laws and regulations applicable to design, manufacture and sale of the Products. XipLink agrees not to export, directly or
indirectly, any U.S. source technical data acquired from Gogo or any products utilizing such data, which export may be in violation of the United States export laws or regulations. 

 

	 	14.3	Notices under this agreement will be in writing, and will be effective when received by confirmed fax or courier delivery, to the address set forth in the
preamble (as may be changed from time to time by notice). Refusal to accept delivery will be deemed receipt. Notices to Gogo will be directed to “Attn: General Counsel”. 

 

	 	14.4	Either party may assign this agreement (a) to an affiliate, provided that the assigning party remains primarily liable for its obligations hereunder, or
(b) to a purchaser of substantially all of the assigning party’s business, upon notice to the nonassigning party, and provided that the purchaser has assumed in writing responsibility for the obligations of the assigning party hereunder.
Neither party may otherwise assign this agreement without the other’s prior written consent, which will not be unreasonably withheld or delayed. Any attempt to assign this agreement in violation of this section will be void. Subject to the
preceding three sentences, this agreement will bind and benefit the permitted assigns and successors in interest of Gogo and XipLink. 

  

	 	14.5	This agreement is governed by the laws of the State of Illinois (without reference to conflict of laws principles). No provision of this agreement may be waived
or modified except (a) as specifically stated herein, or (b) in writing signed by both XipLink and Gogo. This agreement (including the exhibits) is the entire agreement between the parties as to its subject matter, and supersedes any other
negotiations between the parties. Any additional terms in an order form, acceptance form or other communication pursuant to this agreement, other than order quantity and shipping instructions are expressly excluded and will not modify the terms of
this agreement, unless specifically accepted by both parties in writing. This agreement may be executed in counterparts, each of which will constitute an original. If any provision of this agreement is found to be invalid or unenforceable, the
remaining provisions hereof will not be affected. The authority construing this agreement will modify the affected provision to the minimum extent necessary to be valid and enforceable, or if necessary may strike the affected provision and enforce
this agreement as if that provision were not included. The provisions of section 5 and sections 7 through 14 will survive termination of this agreement. Each Party acknowledges that its breach of the Agreement will cause irreparable
damage, and agrees that the other party may be entitled to injunctive relief to enforce or prevent breach of this Agreement, without posting bond, as well as such other relief as may be granted by a court of competent jurisdiction.

  

	 	14.6	Each signer of this agreement warrants that he is duly authorized to sign this agreement on behalf of the party for which he signs, and that this agreement when
executed is binding on the party for which he signs. 

  

	 	14.7	The parties acknowledge that if the U.S. government becomes a purchaser of Gogo’s products of which the Product Units are a component, certain terms
required by the U.S. government may need to be added to the Agreement. Both parties agree to negotiate in good faith the inclusion of such terms to the extent they are reasonably necessary and either (a) do not
materially change the obligations or commercial terms of the Agreement, or (b) are otherwise acceptable to both parties. 

  
 6 

	 	14.8	Trademarks. Gogo hereby grants to XipLink a non-exclusive, limited license to use Gogo’s trademarks, service marks, logos, trade names, and other branding
features (“Gogo Marks”) solely in connection with custom development and branding activities authorized by this Agreement, as specifically set forth in Exhibit B. XipLink shall only use the Gogo Marks in the form and manner as communicated
by Gogo and in accordance with any written trademark usage guidelines provided by Gogo. The use by XipLink of the Gogo Marks in connection with this Agreement shall not create any right, title or interest, in or to the Gogo Marks in favor of XipLink
and all goodwill associated with the use of the Gogo Marks shall inure to the benefit of Gogo. XipLink shall not register, seek to register or contest the validity of the Gogo Marks in any jurisdiction and shall not itself use any name, mark or
designation that is confusingly similar to any of the Gogo Marks. XipLink agrees to use reasonable efforts to protect Gogo’s proprietary rights and to cooperate, without charge, in Gogo’s efforts to protect its proprietary rights. XipLink
agrees to notify Gogo of any known or suspected violation, infringement or misappropriation of Gogo’s proprietary rights which come to XipLink’ attention. 

 

	 	14.9	Limitations of Liability. Both parties’ aggregate liability to the other party and its sub-licensees hereunder, arising out of or related to any provision
of this Agreement, or at law or in equity, excluding any claim arising from Indemnification, or any transaction contemplated by this Agreement, shall be limited to the amount of the license fees paid and/or payable by Gogo to XipLink under this
Agreement in the [***] prior to such claim. 

  

	 	14.10	Indemnification: 12.1. Gogo shall defend, indemnify and hold XipLink and its affiliates harmless against any costs, claims, damages or expenses incurred (and
reasonable attorneys’ fees in connection therewith) in relation to a proceeding or damage to persons or property arising out of or related to a third party claim based on the gross negligence of Gogo or the unauthorized use of the Licensed
Programs, provided that such loss, suit, claim, expense, proceeding or damage (i) is not the subject of indemnity by XipLink under Section 12 or (ii) was not caused solely by the gross negligence of XipLink or of XipLink employees or
representatives, and provided that XipLink: 

  

	 	    	a. promptly notifies Gogo in writing of any such loss, suit, claim, liability, expense (including without limitation reasonable attorney’s fees) or proceeding,

  

	 	    	b. allows Gogo, at Gogo expense, to direct the defense of such suit, claim or proceeding, 

 

	 	    	c. gives Gogo full information and assistance necessary to defend such suit, claim or proceeding, and 

 

	 	    	d. does not enter into any settlement of any such suit, claim or proceeding without Gogo consent. 

 

	 	14.11	Force Majeure. Neither party shall be considered in breach or default under this Agreement for any delay or failure in performance (other than the payment of
money) resulting from acts beyond the control of such party. Such acts shall include but not be limited to acts of God, labour conflicts, acts of war or civil disruption, act of terrorism, governmental regulations imposed after the fact, public
utility failures, industry wide shortages of labour or material, or natural disaster. 

 IN WITNESS WHEREOF, the parties have
executed this Product Development and Manufacturing Agreement as of the date first written above. 
  

									
	XipLink, Inc.	 		 	Gogo LLC
					
	By:	 	  
	 		 	By:	 	  

	Name:	 		 		 	Name:	 	
	Title:	 		 		 	Title:	 	

  
 7 

 Exhibit A to Product Development and Manufacturing Agreement 

Statement of work 
 XA/XE Airlink System Project Outline 
 This Exhibit A is part of the Product
Development and Manufacturing Agreement dated October 3, 2011 between Gogo LLC (‘Gogo”) and XipLink, Inc. (“XipLink”) (the “Agreement”). 

 

	1.	PROJECT BACKGROUND 

 Gogo shall deploy in the next months a new Air-To-Ground (ATG 4) solution that shall incorporate two ATG 4 links. Each ATG 4 link shall be an EVDO RevB Aircard, with peak channel rates of [***] in the FL
and [***] in the RL, however note that the median channel rates shall be closer to [***] in the FL and [***] for the RL. As in any radio network, channel rates shall vary based on RF conditions and the expectation for ATG 4 shall be that each modem
shall vary from 0 to 4.9 Mbps through the flight. 
 [***] 
 [***] 
 This document defines the set of requirements that the XipLink solution must meet for ATG4
solution. 
  

	2.	PROJECT SCOPE AND REQUIREMENTS 

 The ATG system at a high level can be broken up into three parts, a WiFi hotspot, EVDO WAN backhaul and Network Services. A summary of each is given here. 

[***] 
  

	3.	REFERENCES 

 Reference
Documents 
 (None) 
  

	4.	STATEMENT OF WORK MILESTONES 

 

			
	 Projected Timeline
	  	 Target Completion

		
	 PRD Signoff
	  	September 16, 2011
		
	 XE/XA Prototype – Alpha - No new functionality
	  	September 23, 2011
		
	 XE/XA Commercial Release based on PDMA
	  	November 15, 2011
		
	 XE/XA ATP Complete and final signoff and acceptance
	  	December 20, 2011

  
 8 

	5.	PROJECT MANAGEMENT AND COORDINATION 

5.1 Single Point of Contact 
 All
contractual correspondence will be transmitted through a single point of contact for the Gogo and the XipLink. The single point of contact for the Gogo is the Gogo Program Manager and for the XipLink it is the XipLink Program Manager. The key
program personal and contacts are: 
  

							
	 Personnel
	 	 Role
	 	 Telephone
	 	 Email Address

		 	Gogo Program Manager	 		 	
	Bryan Lauer	 	Gogo Technical Lead	 	630.647.1429	 	blauer@Gogoair.com
	Madonna Houser	 	Gogo Contract Manager	 	630.647.1487	 	mhouser@Gogoair.com
	Charlie Younghusband	 	XipLink Program Manager	 	514.848.9640	 	charlie@xiplink.com
	Karim Fodil-Lemelin	 	XipLink Technical Lead	 	514.848.9640	 	kfl@xiplink.com
	Joe Zerucha	 	XipLink Contract Manager	 	514.848.9640	 	jzerucha@xiplink.com
	Jaco Botha	 	XipLink VP of Engineering	 	514.848.9640	 	jbotha@xiplink.com
	Jack Waters	 	XipLink Marketing Manager	 	610.299.4711	 	jwaters@xiplink.com

 5.2 Status Reports and Meetings 
 Microsoft Project shall be used as project-scheduling tool, based upon the initial project plan that has been exchanged between Gogo and XipLink. XipLink shall maintain a detailed project plan that will
specify task dependencies within the project as well as dependencies on Gogo’s activities and commercial item availability. Using this plan as the primary tool, XipLink will be able to modify task orders and priorities as necessary should
changes occur with regard to hardware availability or functionality. XipLink will be able to determine whether or not the allocation of additional human resources to the project would benefit the schedule and will be able to provide Gogo with
bi-weekly updates to the schedule status. 
 5.3 Scope Management 
 During the period of this contract the XipLink shall notify the Gogo Program Manager, in writing, of any activity that is requested that is not covered in the stated requirements for this work scope. If
the Gogo Program Manager determines that the work activity is outside the scope of this contract, then further discussions will be held to clearly define the new requirements and its impact to schedule and cost. If appropriate, this statement of
work will be amended to address the work scope change. No payment will be made for activities performed outside of the scope of this SOW without prior written consent of the Gogo Program Manager and the XipLink Program Manager. 

5.4 Bi-weekly review 
 A bi-weekly
project review meeting will be held between Gogo staff and XipLink staff either by conference call or in person, to cover the following topics in order to ensure the successful project execution: 

 

	1)	Project status and plan 

  

	2)	Resolution of previous issues 

  

	3)	New issues, actions items and risks 

 Additional
meetings may be scheduled as requested by Gogo or XipLink. 
 5.5 Site visitation 

Gogo will have the option to travel to XipLink for the Bi-weekly meetings or any of the Design Reviews. 

 

	6.	VERIFICATION AND VALIDATION TEST CRITERIA 

6.1 Final Acceptance 
 For Final
acceptance of the products, XipLink will: 
  

	 	•	 	 Provide the acceptance test plan (ATP) and test procedures of the Gogo products and Design Verification Test plan to Gogo for review. The ATP test plan
will be executed during the final phase of the project with optional Gogo personnel witness. The ATP test report will be jointly signed off by XipLink. 

 

	 	•	 	 XipLink submits completed Qualification test reports. 

 

	 	•	 	 Manufacture the final Gogo products to conform to the requirements provided by Gogo. 

  
 9 

 6.2 Development & Configuration Control Tools 

XipLink shall have a configuration management system that monitors and maintains configuration, change, and status accounting for hardware within
XipLink’s facility. Gogo shall review and approve all changes and revisions to the products subsequent to Gogo’s completion of First Article Inspection. 
 XipLink shall implement a Quality Assurance system that ensures all products to be delivered hereunder meet the specification requirements and that the products meet the quality standards approved by
Gogo. Gogo will conduct first article inspection. 

  
 10 

	7.	DOCUMENTATION CRITERIA 

 All drawings and documentation required to support the ongoing manufacture and test of Product shall be put into escrow, including but not limited to: 

 

	 	•	 	 Purchase specifications for all components and materials 

 

	 	•	 	 XipLink XA-30K and XE product data sheets 

  

	 	•	 	 Acceptance test plan 

  

	 	•	 	 Any design documentation that is required to support ongoing maintenance of the product. 

 

	8.	FINANCE AND PAYMENT 

 Invoices must reference the appropriate Purchase Order Number, line item and description. The Gogo’s Program Manager will approve all invoices prior to payment. 

Milestone payments will be invoiced upon acceptance of the deliverables for the Phase. Initial payment is due at PRD Sign-Off Date and remaining payments
are due net 45 days from invoice date. The following table defines the amounts to be invoiced at each milestone: 
  

											
	 Phase
	  	 Invoice

#
	  	Amount	 	 	 Milestone
	  	 Date

	 1
	  		  	 	                [***	] 	 	[***]	  	[***]
	 2
	  		  	 	[***	] 	 	[***]	  	[***]

  
 11 

 Exhibit B to 
 Product Development and Manufacturing Agreement 
 Supply and Support
Terms – XipLink XA/XE Airlink Systems 
 This Exhibit B is part of the Product Development and Manufacturing Agreement dated
October 3, 2011 between Gogo LLC (“Gogo”) and XipLink, Inc (“XipLink”) (the “Agreement”). This Exhibit describes the terms of the Agreement relating to manufacturing, supply and support of production units of the
Product developed according to Exhibit A (“Product Units”). 
  

	1.	Manufacturing. XipLink will manufacture or have manufactured under its direct control the Product Units, in facilities that are certifiable as to adherence to
applicable quality and process control standards. Product Units will be manufactured in accordance with the final product specification, and will be tested in accordance with the final Test Plan. Gogo may inspect the manufacturing process and test
the Product Units at any stage upon reasonable notice. XipLink will reasonably cooperate with and assist such inspection and testing without additional charge. Inspection and testing during manufacture does not affect Gogo’s right of inspection
upon delivery. XipLink’s manufacturing quality program will be subject to review and comment by Gogo throughout the life of the Agreement. XipLink will keep Gogo informed of any material change in the materials sourcing or manufacturing process
of the Product Units. XipLink will give Gogo the maximum possible notice (and no less than 90 days) of any plan to discontinue manufacturing of the Product Units. 

 

	2.	Product unit pricing. Pricing for the Product Units will be as follows: 

 

					
	 Product
	  	Pricing	 
		
	 XA-30K/Single Appliance Unit
	  	 	    [***	] 
		
	 XE-CM/B User Software
	  	 	[***	] 
	 XO-XHO30k
	  	 	[***	] 

  

	    	An “aircraft pooled license” allows Gogo to purchase only the number of licenses needed to support the peak concurrent number of aircraft utilizing the XA
systems within the entire Gogo network. The XA appliance shall not set any capacity or session limit related to the purchased licensed capacity, Gogo may exceed the licensed capacity until the next audit, to be held quarterly every three months, and
purchase of XE-CM licensing. 

  

	3.	Minimum Quantity and Initial Purchase Discount. Subject to the terms of this agreement and subject to final Product Acceptance, Gogo commits to order a minimum
of four (4) XA-30K/Single Appliance Product Units for delivery upon Product Acceptance. The initial PO will be submitted promptly after Product Acceptance. XipLink agrees that the purchase price for the initial four XA-30K/Single Appliance
Product Units shall be discounted [***] for an aggregate purchase price of [***]. The purchase price for the initial four units is included in the Milestone Payments set forth in the Section 8 the Finance & Payment provision of Exhibit
A. Each subsequent PO for XA-30K/Single Appliance Product Units will specify a first delivery date not more than 30 days after the PO is placed, and a last delivery date not more than 90 days after the PO is placed. 

 

	    	 Subject to the terms of this agreement and subject to final Product Acceptance, Gogo commits to order a minimum of 100 client aircraft licenses of the
XE-CM/B User Software for delivery upon 

  
 12 

	 	
Product Acceptance. The purchase price for the initial 100 client aircraft licenses of the XE-CM/B User Software is included in the Milestone Payments set forth in the Section 8 the
Finance & Payment provision of Exhibit A. The license is a pooled capacity license and is only chargeable on the utilization and capacity of the server farm. If the utilization capacity exceeds 100 clients at any time in a calendar quarter,
Gogo shall purchase an additional client aircraft licenses in 100 client blocks at the commencement of the calendar quarter following the capacity overage. 

 

	4.	Product support. During the first twelve months after Product Acceptance, XipLink will provide support services free of charge (by telephone or email) for issues
that are not covered under the product warranty. The Support Services include: 

  

	 	•	 	 Tier two technical support on calls from Gogo personnel only. 

 

	 	•	 	 Software upgrades 

  

	 	•	 	 Engineering support for Gogo’s certification effort regarding devices of which the Product is a component 

 

	 	•	 	 Resolution of system-wide issues 

  

	 	•	 	 Troubleshooting and bug fixes 

 XipLink will be available to provide the Support Services in the English language, twenty-four hours per day, seven days a week except for statutory Canadian Holidays. XipLink’s response time for
support requests by telephone or email will not exceed four business hours for any support issue involving a nonfunctioning Product Unit, or one business day for all other issues. For any support issue involving a nonfunctioning Product Unit,
XipLink will apply continuous efforts during business hours from initiation of the trouble ticket to resolution. The parties will jointly define a Support Services process to suit Gogo needs including bug priority, resolution time, and escalation.
Gogo may renew the Support Services contract annually after the first year, for compensation as mutually agreed. 
  

	5.	Training and Installation Services. XipLink will conduct training for the Gogo team as mutually agreed. Travel expenses will be paid by Gogo as stated in
section 8 of Exhibit A. These trainings will be free of charge, on dates to be agreed. XipLink will provide engineering support for installation of Product Units at a price of [***] per week of onsite support. 

 

	6.	Warranty support. The Product Units are warranted as described in Section 5 of the Agreement. After the one year no cost warranty period, XipLink will
provide TAC support services, comprised of call-in support, bug fixes, new features, customer web portal and document update service at a cost to Gogo of no greater than [***] of the initial cost of such Product unit. Extended hardware warranty is
not elected at this time, although units are fully warranted from hardware defects for 12 months from delivery. Gogo will notify XipLink in the case of any suspected defective units, and will arrange for the return of such units for disposition
under an RMA number. Gogo will ship returned units at Gogo’s expense and risk. XipLink will complete its warranty disposition and ship any repaired or replacement Product Unit no later than thirty (30) business days after receipt of
the returned unit. XipLink will ship repaired or replacement units at XipLink’s expense and risk, by the same shipment method Gogo used for the return. All Product Unit repairs will be performed using new (not reconditioned) components of equal
or greater quality. Repaired or replaced Product Units will be tested prior to shipment in accordance with the procedures for new Product Units. Repaired or replaced Product Units will be warranted for the remainder of the original warranty period.

  

	7.	 Scheduling. XipLink’s manufacturing lead time for Product Units will be 60 days from receipt of Gogo’s PO to date of delivery.
Gogo may accelerate delivery of Product Units ordered, provided that the accelerated schedule provides XipLink with 30 days lead-time. Gogo may delay delivery of Product Units ordered, provided that orders may not be delayed or cancelled after
shipment. XipLink will attempt to accommodate any other scheduling request of Gogo, subject to reasonable fees for 

  
 13 

	 	
expedited production and delivery. Gogo reserves the right to return at XipLink’s expense any Product Units shipped more than five (5) days ahead of the required date of delivery as
stated in the PO, unless such advance shipment has been specifically authorized by Gogo. 

  

	8.	Shipment. Product Units will be individually packaged according to the applicable specifications. PO numbers will be prominently displayed on package labeling.
Title and risk of loss will remain with XipLink until delivery to the carrier. Product Units are received subject to inspection. Gogo will contact XipLink and receive a Returned Material Authorization (RMA) number before returning Product Units.

  

	9.	Terms of sale. Gogo will be invoiced on shipment of Product Units. All freight or insurance charges will be paid by Gogo. Gogo will not be responsible for any
taxes imposed on XipLink, and XipLink will not impose packing or other incidental charges. XipLink will process all paperwork and pay all government charges and all other fees (such as forwarding agent fees) relating to export of Product Units from
Montreal, Quebec, Canada and import of Product Units into the US. Gogo will reimburse XipLink for all government charges relating to import of Product Units into the US, and for all reasonable fees referred to in the preceding sentence, which will
be listed separately on XipLink’s invoice. XipLink will be responsible for government charges relating to export. 

  
 14EX-10.1.43

 Exhibit 10.1.43 

Single Licensee 
 Software Escrow Agreement 
  

			
	 Date
	  	February 2, 2013
		
	 Licensor
	  	XipLink, Inc.
		
	 Licensee
	  	Gogo LLC
		
	 Agreement Number
	  	Product Development and Manufacturing Agreement

 Notice: The parties to this Agreement are obliged to inform Escrow Agent of any changes to the Software or in their
circumstances (including change of name, principal office, contact details or change of owner of the intellectual property in the Software). 

 Escrow Agreement Dated: 
 Between: 
  

	(1)	XipLink, Inc. whose principal office is at 3981 St. Laurent Blvd., Suite 800, Montreal, QC H2W 1Y5 (“Licensor”); 

 

	(2)	Gogo LLC whose principal office is at 1250 N. Arlington Heights Road, Itasca, IL 60143 (“Licensee”); and 

 

	(3)	NCC Group Escrow Associates, LLC, a corporation organized and existing under the laws of Georgia with its principal office at 8302 Dunwoody Place, Suite 150, Atlanta GA
30350, USA (“Escrow Agent”). 

 Background: 

 

	(A)	Licensee has been granted a license to use the Software which comprises computer programs. 

 

	(B)	Certain technical information and/or documentation relating to the Software is the confidential information and intellectual property of Licensor or a third party.

  

	(C)	Licensor acknowledges that in certain circumstances, such information and/or documentation would be required by Licensee in order for it to continue to exercise its
rights under its License Agreement with the Licensor. 

  

	(D)	The parties therefore agree that such information and/or documentation should be placed with a trusted third party, Escrow Agent, so that such information and/or
documentation can be released to Licensee should certain circumstances arise. 

 Agreement: 

In consideration of the mutual undertakings and obligations contained in this Agreement, the parties agree that: 

 

	1	Definitions and Interpretation 

  

	 	1.1	In this Agreement the following terms shall have the following meanings: 

  

	 	    	“Agreement” means the terms and conditions of this single licensee software escrow agreement set out below, including the Schedule(s) hereto.

  

	 	    	“Confidential Information” means all technical and/or commercial information not in the public domain and which is designated in writing as
confidential by any party. 

  

	 	    	“Deposit Form” means the form at Schedule 1 which is to be completed by Licensor and delivered to Escrow Agent with each deposit of the Escrow
Material. 

  
 2 of 17

	 	    	“Escrow Material” means the Source Code of the Software and such other material and documentation (including updates and upgrades thereto and new
versions thereof) as are necessary to be delivered or deposited to comply with Clause 2 of this Agreement. 

  

	 	    	“Full Verification” means the tests and processes forming Escrow Agent’s Full Verification service and/or such other tests and processes as may be
agreed between the parties for the verification of the Escrow Material. 

  

	 	    	“Integrity Testing” means those tests and processes forming Escrow Agent’s Integrity Testing service, in so far as they can be applied to the
Escrow Material. 

  

	 	    	“Intellectual Property Rights” mean any copyright, patents, design patents, registered designs, design rights, utility models, trademarks, service
marks, trade secrets, know how, database rights, moral rights, confidential information, trade or business names, domain names, and any other rights of a similar nature including industrial and proprietary rights and other similar protected rights
in any country or jurisdiction together with all registrations, applications to register and rights to apply for registration of any of the aforementioned rights and any licenses of or in respect of such rights. 

 

	 	    	“License Agreement” means the agreement under which Licensee was granted a license to use the Software. 

 

	 	    	“Letter of Intent” means the form completed by Licensor and/or Licensee containing the information, including the fee schedule for services to be
provided hereunder, to enable Escrow Agent to set up this Agreement. 

  

	 	    	“Release Purposes” means the purposes of understanding, maintaining, modifying and correcting the Software exclusively for and on behalf of Licensee
together with such other purposes (if any) as are permitted under the License Agreement. 

  

	 	    	“Software” means the software together with any updates and upgrades thereto and new versions thereof licensed to Licensee under the License Agreement
details of which are set out in Schedule 1. 

  

	 	    	“Source Code” means the computer programming code of the Software in human readable form. 

 

	 	1.2	This Agreement shall be interpreted in accordance with the following: 

  

	 	1.2.1	headings are for ease of reference only and shall not be taken into consideration in the interpretation of this Agreement; 

 

	 	1.2.2	all references to Clauses and Schedules are references to Clauses and Schedules of this Agreement; and 

 

	 	1.2.3	all references to a party or parties are references to a party or parties to this Agreement. 

  
 3 of 17

	2	Licensor’s Duties and Warranties 

  

	 	2.1	Licensor shall; 

  

	 	2.1.1	deliver a copy of the Escrow Material to Escrow Agent within 30 days of the date of this Agreement; 

 

	 	2.1.2	deliver an update or replacement copy of the Escrow Material to Escrow Agent within 30 days of a material update, error correction, enhancement, maintenance release or
functional modification to the Software which results in an updated delivery of the object code version of the Software to Licensee; 

  

	 	2.1.3	ensure that each copy of the Escrow Material deposited with Escrow Agent comprises the Source Code of the latest version of the Software used by Licensee;

  

	 	2.1.4	deliver to Escrow Agent an update or replacement copy of the Escrow Material within 30 days after the anniversary of the last delivery of the Escrow Material to ensure
that the Escrow Material represents the most current version of Source Code and that the integrity of the Escrow Material media is maintained; 

  

	 	2.1.5	deliver with each deposit of the Escrow Material a Deposit Form which includes the following information: 

 

	 	2.1.5.1	details of the deposit including the full name of the Software (i.e. the original name as set out under Schedule 1 together with any new names given to the Software by
Licensor), version details, media type, backup command/software used, compression used, archive hardware and operating system details; and 

  

	 	2.1.5.2	password/encryption details required to access the Escrow Material; 

  

	 	2.1.6	deliver with each deposit of the Escrow Material the following technical information (where applicable): 

 

	 	2.1.6.1	documentation describing the procedures for building, compiling and installing the Software, including names and versions of the development tools;

  

	 	2.1.6.2	Software design information (e.g. module names and functionality); and 

  

	 	2.1.6.3	name and contact details of employees with knowledge of how to maintain and support the Escrow Material; and 

 

	 	2.1.7	deposit a detailed list of the suppliers of any third party software or tools, including open source software and tools, required to access, install, build or compile
or otherwise use the Escrow Material. 

  
 4 of 17

	 	2.2	Licensor warrants to both Escrow Agent and Licensee at the time of each deposit of the Escrow Material with Escrow Agent that: 

 

	 	2.2.1	it has the full right, ability and authority to deposit the Escrow Material; 

 

	 	2.2.2	in entering into this Agreement and performing its obligations under it, it is not in breach of any of its ongoing express or implied obligations to any third party(s);
and 

  

	 	2.2.3	the Escrow Material deposited under Clause 2.1 contains all information in human-readable form and is on suitable media to enable a reasonably skilled programmer or
analyst to understand, maintain, modify and correct the Software. 

  

	3	Licensee’s Responsibilities and Undertakings 

  

	 	3.1	Licensee shall notify Escrow Agent of any change to the Software that necessitates a replacement deposit of the Escrow Material. 

 

	 	3.2	In the event that the Escrow Material is released under Clause 6, Licensee shall: 

 

	 	3.2.1	keep the Escrow Material confidential at all times; 

  

	 	3.2.2	use the Escrow Material only for the Release Purposes; 

  

	 	3.2.3	not disclose the Escrow Material to any person save such of Licensee’s employees or contractors who need to know the same for the Release Purposes. In the event
that Escrow Material is disclosed to its employees or contractors, Licensee shall ensure that they are bound by the same confidentiality obligations as are contained in this Clause 3.2; 

 

	 	3.2.4	hold all media containing the Escrow Material in a safe and secure environment when not in use; and 

 

	 	3.2.5	forthwith destroy the Escrow Material should Licensee cease to be entitled to use the Software under the terms of the License Agreement. 

 

	4	Escrow Agent’s Duties 

  

	 	4.1	Escrow Agent shall: 

  

	 	4.1.1	at all times during the term of this Agreement, retain the Escrow Materiel in a safe and secure environment; and 

 

	 	4.1.2	inform Licensor and Licensee of the receipt of any deposit of the Escrow Material by sending to both parties a copy of the Deposit Form, and/or the Integrity Testing
report or Full Verification report (as the case may be) generated from the testing processes carried out under Clause 10. 

  

	 	4.2	In the event of failure by Licensor to deposit any Escrow Material with Escrow Agent, Escrow Agent shall not be responsible for procuring such deposit and may, at its
sole discretion, notify the Licensor and Licensee of Licensor’s failure to deposit any Escrow Material. 

  
 5 of 17

	 	4.3	Escrow Agent may appoint agents, contractors or sub-contractors as it deems fit to carry out the Integrity Testing and the Full Verification processes. Escrow Agent
shall ensure that any such agents, contractors and sub-contractors are bound by the same confidentiality obligations as are contained in Clause 8. 

  

	 	4.4	Escrow Agent has the right to make such copies of the Escrow Material as may be necessary solely for the purposes of this Agreement. 

 

	5	Payment 

  

	 	5.1	The parties shall pay Escrow Agent’s fees and charges as published from time to time or as otherwise agreed, as listed in the Letter of Intent between the parties.
Escrow Agent’s fees as published are exclusive of any applicable sales tax. 

  

	 	5.2	Escrow Agent shall be entitled to review and vary its standard fees and charges for its services under this Agreement from time to time but no more than once a year and
only upon 45 days written notice to the parties. 

  

	 	5.3	All invoices are payable within 30 days from the date of invoice. Interest shall accrue at the lesser of 1.5% per month or the maximum amount permitted by
applicable law for any fees that are undisputed by the paying party and remain unpaid for more than 30 days past the due date of the applicable invoice. 

  

	 	5.4	In the event of a dispute made in good faith as to the amount of fees, the party responsible for payment agrees to remit payment on any undisputed amount(s) in
accordance with Clause 5.1 above. In such circumstances, the interest on the fees shall not accrue as to any disputed amounts unless not paid within 30 days after such dispute has been resolved by the parties. 

 

	6	Release Events and Procedures 

  

	 	6.1	Subject to: (i) the remaining provisions of this Clause 6 and (ii) the receipt by Escrow Agent of the fees chargeable upon a release and any other fees and
interest (if any) outstanding under this Agreement, Escrow Agent will release the Escrow Material to a duly authorized representative of Licensee if any of the following events (“Release Event(s)”) occur: 

 

	 	6.1.1	a receiver, trustee, or similar officer is appointed for the business or property of Licensor; or 

 

	 	6.1.2	Licensor files a petition in bankruptcy, files a petition seeking any reorganization (without confirming immediately in writing to Licensee that it will continue to
maintain the Software in accordance with the terms of the License Agreement or any applicable maintenance agreement), makes an arrangement, composition, or similar relief under any law regarding insolvency or relief for debtors, or makes an
assignment for the benefit of creditors; 

  
 6 of 17

	 	6.1.3	or any involuntary petition or proceeding under bankruptcy or insolvency laws is instituted against Licensor and not stayed, enjoined, or discharged within 60 days; or

  

	 	6.1.4	Licensor takes any corporate action authorizing any of the foregoing; or 

  

	 	6.1.5	any similar or analogous proceedings or event to those in Clauses 6.1.1 to 6.1.3 above occurs in respect of Licensor within any jurisdiction outside the USA; or

  

	 	6.1.6	Licensor ceases to carry on its business or the part of its business which relates to the Software; or 

 

	 	6.1.7	Licensor or, where relevant, its agent, parent, subsidiary or associated company is in material breach of its obligations as to maintenance or modification of the
Software under the License Agreement or any maintenance agreement entered into in connection with the Software and has failed to remedy such default notified by Licensee to Licensor within the time period specified in the License Agreement or any
maintenance agreement or other relevant agreement, and if no time period is specified, within a commercially reasonable time period. 

  

	 	6.2	Licensee must notify Escrow Agent and Licensor of the Release Event specified in Clause 6.1 by delivering to Escrow Agent a notice in writing (“Notice”)
declaring that such Release Event has occurred, setting out the facts and circumstances of the Release Event, that the License Agreement and any maintenance agreement, if relevant, for the Software was still valid and effective up to the occurrence
of such Release Event and exhibiting such documentary evidence in support of the Notice as Escrow Agent shall reasonably require. 

  

	 	6.3	Upon receipt of a Notice from Licensee claiming that a Release Event has occurred: 

 

	 	6.3.1	Escrow Agent shall submit a copy of the Notice to Licensor (with a copy to the Licensee in order to acknowledge receipt of the Notice) by courier or other form of
guaranteed delivery; and 

  

	 	6.3.2	unless within 14 calendar days after the date of dispatch of the Notice by Escrow Agent, Escrow Agent receives a counter-notice in writing from Licensor stating that in
their view no such Release Event has occurred or, if appropriate, that the event or circumstance giving rise to the Release Event has been rectified as shown by documentation in support thereof, Escrow Agent will release the Escrow Material to
Licensee for its use for the Release Purposes. 

  

	 	6.4	Upon receipt of the counter-notice from Licensor under Clause 6.3.2, Escrow Agent shall send a copy of the counter-notice and any supporting evidence to Licensee (with
a copy to Licensor in order to acknowledge receipt of the counter-notice) by courier or other form of guaranteed delivery. 

  
 7 of 17

	 	6.5	Within 90 calendar days of dispatch of the counter-notice by Escrow Agent, Licensee may give Licensor and Escrow Agent written notice of its intention to arbitrate
under Clause 7 (“Demand’). 

  

	 	6.6	If, within 90 calendar days of dispatch of the counter-notice by Escrow Agent to Licensee, Licensee has not given a Demand to Licensor and Escrow Agent, the Notice
submitted by Licensee will be deemed to be no longer valid and Licensee shall be deemed to have waived their right to release of the Escrow Material for the particular reason or event specified in the original Notice. In such circumstances, this
Agreement shall continue in full force and effect. 

  

	7	Disputes regarding Release Event(s) 

  

	 	7.1	All disputes regarding whether the Release Event(s) specified in the Notice occurred before the Licensee delivered the Notice to Escrow Agent shall be decided by one
(1) arbitrator. The place of the arbitration shall be Atlanta, Georgia. If the Licensor and Licensee have not agreed on an arbitrator within seven (7) days after the Licensor receives the Demand, the American Arbitration Association (AAA)
shall appoint an arbitrator within ten (10) days of receipt of a request to appoint an arbitrator, which may be filed by either the Licensor or Licensee. The arbitrator’s agreement to the deadlines set forth in this Clause 7 shall be a
condition to the appointment as arbitrator, but failure to adhere to these time limits shall not be a basis for challenging the award. 

  

	 	7.2	Within seven (7) days of the appointment of the arbitrator, the Licensor and Licensee shall each provide written submissions to the arbitrator, together with all
documentary evidence in their possession in support of their claim. 

  

	 	7.3	Based solely on the written submissions of the Licensor and Licensee, and without the need for a hearing, the arbitrator shall render and deliver his or her award to
the Licensor, the Licensee and Escrow Agent within fourteen (14) days of receiving the written submissions from the Licensor and Licensee. The Licensee and Licensor may agree to extend this time limit or the arbitrator may do so in its
discretion if he or she determines that the interest of justice so requires. 

  

	 	7.4	The award shall be limited to a determination of whether or not there existed a Release Event at the time Licensee delivered the Notice to Escrow Agent and, where the
Licensor claims within the timescales specified in Clause 6.3.2 that the Release Event has been rectified and the Licensee does not agree, to a determination of whether or not the Release Event has in fact been rectified. In addition, the arbitrator
shall award the prevailing party its attorneys’ fees and costs, including the fees and costs of the arbitrator. 

  

	 	7.5	The arbitral award shall be final and binding upon the Parties hereto. If the arbitrator finds that a Release Event existed at the time of delivery of the Notice to
Escrow Agent, Escrow Agent is hereby authorized to release and deliver the Escrow Material to the Licensee within 5 working days of the decision being notified by the arbitrator to the parties. If the arbitrator finds to the contrary, then Escrow
Agent shall not release the Escrow Material and shall continue to hold the Escrow Material in accordance with the terms of this Agreement. 

  

	 	7.6	The Parties agree that the arbitration provided in this Clause 7 shall not be consolidated or joined with any other proceeding regarding disputes between or among any
of the Parties. 

  
 8 of 17

	8	Confidentiality 

  

	 	8.1	The Escrow Material shall remain at all times the confidential and intellectual property of its owner. 

 

	 	8.2	In the event that Escrow Agent releases the Escrow Material to Licensee, Licensee shall be permitted to use the Escrow Material only for the Release Purposes.

  

	 	8.3	Subject to Clause 8.4, Escrow Agent agrees to keep all Confidential Information relating to the Escrow Material and/or the Software that comes into its possession or to
its knowledge under this Agreement in strict confidence and secrecy. Escrow Agent further agrees not to make use of such information and/or documentation other than for the purposes of this Agreement and, unless the parties should agree otherwise in
writing and subject to Clause 8.4, will not disclose or release it other than in accordance with the terms of this Agreement. 

  

	 	8.4	Escrow Agent may release the Escrow Material to the extent that it is required by applicable federal, state or local law, regulation, court order, judgment, decree or
other legal process, provided that, unless prohibited by the terms of the order or the relevant law or regulation, Escrow Agent has notified Licensor and Licensee prior to such required release, has given Licensor and/or Licensee an opportunity to
contest (at their own expense) such required release, within the time parameters mandated by such applicable regulation, court order, judgment, decree or other legal process, Escrow Agent is hereby expressly authorized in its sole discretion to obey
and comply with all orders, judgments, decrees so entered or issued by any court, without the necessity of inquiring as to the validity of such order, judgment or decree, or the court’s underlying jurisdiction. Where Escrow Agent obeys or
complies with any such order, judgment or decree, Escrow Agent shall not be liable to Licensee, Licensor or any third party by reason of such compliance, notwithstanding that such order, judgment or decree may subsequently be reversed, modified or
vacated. 

  

	9	Intellectual Property Rights 

  

	 	9.1	The release of the Escrow Material to Licensee will not act as an assignment of any Intellectual Property Rights that Licensor or any third party possesses in the
Escrow Material. However, upon deposit of the Escrow Material, the title to the media upon which the Escrow Material is deposited (“Media”) is transferred to Escrow Agent. Upon delivery of the Escrow Material back to Licensor, the title to
the Media shall transfer back to the Licensor. If the Escrow Material is released to the Licensee, the title to the Media shall transfer to the Licensee. 

  

	 	9.2	The Intellectual Property Rights in the Integrity Testing report and any Full Verification report shall remain vested in Escrow Agent. Licensor and Licensee shall each
be granted a non-exclusive right and license to use such report for the purposes of this Agreement and their own internal purposes only. 

  
 9 of 17

	10	Integrity Testing and Full Verification 

  

	 	10.1	Escrow Agent shall bear no obligation or responsibility to any party to this Agreement or person, firm, company or entity whatsoever to determine the existence,
relevance, completeness, accuracy, operation, effectiveness, functionality or any other aspect of the Escrow Material received by Escrow Agent under this Agreement. 

 

	 	10.2	As soon as practicable after the Escrow Material has been deposited with Escrow Agent, Escrow Agent shall apply its Integrity Testing processes to the Escrow Material.

  

	 	10.3	Any party to this Agreement shall be entitled to require Escrow Agent to carry out a Full Verification. Subject to Clause 10.4, Escrow Agent’s prevailing fees and
charges for the Full Verification processes and all reasonable expenses incurred by Escrow Agent in carrying out the Full Verification processes shall be payable by the requesting party. 

 

	 	10.4	If the Escrow Material fails to satisfy Escrow Agent’s Full Verification tests within the timescales originally provided for the completion of the Full
Verification test as a result of being defective or incomplete in content, Escrow Agent’s fees, charges and expenses in relation to the Full Verification tests shall be paid by Licensor. 

 

	 	10.5	Should the Escrow Material deposited fail to satisfy Escrow Agent’s Integrity Testing or Full Verification tests under Clauses 10.2 or 10.3, Licensor shall, within
14 days of the receipt of the notice of test failure from Escrow Agent, deposit such new, corrected or revised Escrow Material as shall be necessary to ensure its compliance with its warranties and obligations in Clause 2. If Licensor fails to make
such deposit of the new, corrected or revised Escrow Material, Escrow Agent will issue a report to Licensee (with a copy to Licensor) detailing the problem with the Escrow Material as revealed by the relevant tests. 

 

	11	Escrow Agent’s Liability 

  

	 	11.1	Nothing in this Clause 11 excludes or limits the liability of Escrow Agent for gross negligence or intentional misconduct. 

 

	 	11.2	Subject to Clause 11.1, Escrow Agent shall not be liable for: 

  

	 	11.2.1	any loss or damage caused to either Licensor or Licensee except to the extent that such loss or damage is caused by the negligent acts or omissions of or a breach of
any contractual duty by Escrow Agent, its employees, agents or sub-contractors and in such event Escrow Agent’s total liability with regard to all claims arising under or by virtue of this Agreement or in connection with the performance or
contemplated performance of this Agreement, shall not exceed the sum of 5250,000 (two hundred and fifty thousand US dollars); and 

  

	 	11.2.2	any special, indirect, incidental or consequential damages whatsoever. 

  
 10 of 17

	 	11.3	Escrow Agent shall not be responsible in any manner whatsoever for any failure or inability of Licensor or Licensee to perform or comply with any provision of this
Agreement. 

  

	 	11.4	Escrow Agent shall not be liable in any way to Licensor or Licensee for acting in accordance with the terms of this Agreement and specifically (without limitation) for
acting upon any notice, written request, waiver, consent, receipt, statutory declaration or any other document furnished to it pursuant to and in accordance with this Agreement. 

 

	 	11.5	Escrow Agent shall not be required to make any investigation into and shall be entitled in good faith without incurring any liability to Licensor or Licensee to assume
(without requesting evidence thereof) the validity, authenticity, veracity and due and authorized execution of any documents, written requests, waivers, consents, receipts, statutory declarations or notices received by it in respect of this
Agreement. 

  

	12	Indemnity 

  

	 	12.1	Save for any claim falling within the provisions of Clause 11 1, the Licensor and the Licensee jointly and severally agree at all times to indemnify and hold harmless
Escrow Agent in respect of all of its legal and all other costs (including reasonable attorney’s fees), fees and expenses incurred directly or indirectly as a result of being brought into or otherwise becoming involved in any form of dispute
resolution proceedings or any litigation of any kind between the Licensor and the Licensee in relation to this Agreement to the extent that this Agreement does not otherwise provide for reimbursement of such costs. 

 

	 	12.2	The Licensor shall assume all liability and shall at all times indemnify and hold harmless Escrow Agent and its officers, agents, sub-contractors and employees from and
against any and all liability, loss, damages, costs, legal costs (including reasonable attorney’s fees), professional and other expenses and any other liabilities of whatever nature, awarded against or agreed to be paid or otherwise suffered,
incurred or sustained by Escrow Agent, whether direct, indirect or consequential as a result of or in connection with any claim by any third party(s) for alleged or actual infringement of Intellectual Property Rights arising out of or in connection
with all and any acts or omissions of Escrow Agent in respect of the Escrow Material as contemplated under this Agreement. 

  

	13	Term and Termination 

  

	 	13.1	This Agreement shall continue until terminated in accordance with this Clause 13. 

 

	 	13.2	Licensee may terminate this Agreement at any time by giving sixty (60) days prior written notice to Escrow Agent. Upon such termination, Escrow Agent shall, unless
it receives written instructions to the contrary from the Licensor within 30 days of the date of termination, destroy the Escrow Material. 

  

	 	13.3	 If the License Agreement has expired or has been lawfully terminated, then either party (the “Requesting Party”) shall have the right to give
notice to Escrow Agent 

  
 11 of 17

	 	
requesting termination of this Agreement. Upon receipt of such a notice from the Requesting Party, Escrow Agent shall notify the other party (the “Receiving Party”) of the Requesting
Party’s notice to terminate. Unless within 30 days of Escrow Agent giving such notice to the Receiving Party, Escrow Agent receives a counter-notice from the Receiving Party disputing the termination of the License Agreement, then the parties
shall be deemed to have consented to such termination and this Agreement shall immediately automatically terminate. Upon termination under this Clause, Escrow Agent shall destroy the Escrow Material. 

 

	 	13.4	Subject to Clause 13.3, Licensor may only terminate this Agreement with the written consent of Licensee. 

 

	 	13.5	This Agreement shall automatically immediately terminate upon release of the Escrow Material to Licensee in accordance with Clause 6. 

 

	 	13.6	If Licensor or Licensee, as the case may be, fails to pay an invoice addressed to it for services under this Agreement in accordance with the terms of Clause 5, Escrow
Agent reserves the right to give that party written notice to pay the outstanding invoice within 30 days. If Licensor has not paid its invoice by the expiry of the 30 day notice period, Escrow Agent will give Licensee a period of 30 days to pay
Licenser’s invoice. If Licensor or Licensee (as appropriate) has not paid its invoice after being given notice in accordance with this Clause, Escrow Agent shall have the right to terminate this Agreement without further notice. Any amounts
owed by Licensor but paid by Licensee will be recoverable by Licensee direct from Licensor as a debt and, if requested, Escrow Agent shall provide appropriate documentation to assist in such recovery. 

 

	 	13.7	Upon termination under the provisions of Clauses 13.4 or 13.6 and in the event of termination under Clause 13.5 where Licensee does not require release of all of
the Escrow Material, for 30 days from the date of termination Escrow Agent will make the Escrow Material available for collection by Licensor or its agents from the premises of Escrow Agent during office hours. After such 30 day period Escrow Agent
has the authority to destroy the Escrow Material. 

  

	 	13.8	Notwithstanding any other provision of this Clause 13, Escrow Agent may resign as Escrow Agent hereunder and terminate this Agreement by giving sixty (60) days
written notice to Licensor and Licensee (“Resignation Notice”). In that event, Licensor and Licensee shall have the option to appoint a mutually acceptable new custodian on similar terms and conditions to those contained herein. If a new
custodian is not appointed within fourteen (14) days of delivery of the Resignation Notice or a longer period as agreed by Licensor and Licensee, Licensor or Licensee shall be entitled to request the American Arbitration Association to appoint
a suitable new custodian upon terms and conditions consistent with those in this Agreement. Such appointment shall be final and binding on Licensor and Licensee. If Escrow Agent is notified of the new custodian sixty (60) days of giving the
Resignation Notice, Escrow Agent will forthwith deliver the Escrow Material to the new custodian. If Escrow Agent is not notified of the new custodian within the aforementioned notice period, Escrow Agent will destroy the Escrow Material.

  

	 	13.9	The provisions of Clauses 1, 3.2, 5, 8, 9, 10.1, 11, 12, 13.9 to 13.11 (inclusive) and 14 shall continue in full force after termination of this Agreement.

  
 12 of 17

	 	13.10	On and after termination of this Agreement, Licensor and/or Licensee (as appropriate) shall remain liable to Escrow Agent for payment in full of any fees and interest
which have become due but which have not been paid as at the date of termination. 

  

	 	13.11	The termination of this Agreement, however arising, shall be without prejudice to the rights accrued to the parties prior to termination. 

 

	14	General 

  

	 	14.1	A party shalt notify the other parties to this Agreement, within 30 days of its occurrence, of any of the following: 

 

	 	14.1.1	a change of its name, principal office, contact address or other contact details; and 

 

	 	14.1.2	any material change in its circumstances that may affect the validity or operation of this Agreement. 

 

	 	14.2	This Agreement shall be deemed entered into in California and will be governed by and construed according to the laws of the state of Georgia, excluding that body of
law known as conflict of law. The parties agree that any dispute arising under this Agreement, except as provided in Clause 7, will be resolved in the state or federal courts in Atlanta, Georgia, and the parties hereby expressly consent to the
jurisdiction thereof. 

  

	 	14.3	This Agreement, together with the Letter of Intent and any relevant Escrow Agent standard terms and conditions including Escrow Agent escrow terms and conditions and,
where applicable, Escrow Agent verification terms and conditions represent the whole agreement relating to the escrow arrangements between Escrow Agent and the other parties for the Software and shall supersede all prior agreements, discussions,
arrangements, representations, negotiations and undertakings. In the event of any conflict between any of these documents, the terms of this Agreement shall prevail. 

 

	 	14.4	Unless the provisions of this Agreement otherwise provide, any notice or other communication required or permitted to be given or made in writing hereunder shall be
validly given or made if delivered by hand or courier or if dispatched by certified or registered mail (airmail if overseas) addressed to the address specified for the parties in this Agreement (or such other address as may be notified to the
parties from time to time) or if sent by facsimile message to such facsimile number as has been notified to the parties from time to time and shall be deemed to have been received; 

 

	 	(i)	if delivered by hand or courier, at the time of delivery; 

  

	 	(ii)	if sent by certified or registered mail (airmail if overseas), 3 business days after posting (6 days if sent by airmail); 

 

	 	(iii)	if sent by facsimile, at the time of completion of the transmission of the facsimile with facsimile machine confirmation of transmission to the correct facsimile number
of all pages of the notice. 

  
 13 of 17

	 	14.5	Except where any party merges, is acquired or has substantially all of its assets acquired and the new entity or acquirer agrees to assume all of their obligations and
liabilities under this Agreement, no party shall assign, transfer or subcontract this Agreement or any rights or obligations hereunder without the prior written consent of the other parties. 

 

	 	14.6	This Agreement shall be binding upon and survive for the benefit of the successors in title and permitted assigns of the parties. 

 

	 	14.7	If any provision of this Agreement is declared too broad in any respect to permit enforcement to its full extent, the parties agree that such provision shall be
enforced to the maximum extent permitted by law and that such provision shall be deemed to be varied accordingly. If any provision of this Agreement is found by any court, tribunal or administrative body of competent jurisdiction to be wholly or
partly illegal, invalid, void or unenforceable, it shall, to the extent of such illegality, invalidity or unenforceability, be deemed severable and the remaining part of the provision and the rest of the provisions of this Agreement shall continue
in full force and effect. 

  

	 	14.8	Save as expressly provided in this Agreement, no amendment or variation of this Agreement shall be effective unless in writing and signed by a duly authorized
representative of each of the parties to it. 

  

	 	14.9	The parties shall not be liable to each other or be deemed to be in breach of this Agreement by reason of any delay in performing, or failure to perform, any of their
obligations under this Agreement if the delay or failure was for a reason beyond that party’s reasonable control (including, without limitation, fire, flood, explosion, epidemic, riot, civil commotion, any strike, lockout or other industrial
action, act of God, war or warlike hostilities or threat of war, terrorist activities, accidental or malicious damage, or any prohibition or restriction by any governments or other legal authority which affects this Agreement and which is not in
force on the date of this Agreement). A party claiming to be unable to perform its obligations under this Agreement (either on time or at all) in any of the circumstances set out above must notify the other parties of the nature and extent of the
circumstances in question as soon as practicable. If such circumstances continue for more than six months, any of the other parties shall be entitled to terminate this Agreement by giving one month’s notice in writing. 

 

	 	14.10	No waiver by any party of any breach of any provisions of this Agreement shall be deemed to be a waiver of any subsequent or other breach and, subject to Clause 6.6, no
failure to exercise or delay in exercising any right or remedy under this Agreement shall constitute a waiver thereof. 

  

	 	14.11	This Agreement may be executed in any number of counterparts and by different parties in separate counterparts. Each counterpart when so executed shall be deemed to be
an original and all of which together shall constitute one and the same agreement. 

  
 14 of 17

	 	14.12	Notices— 

  

							
	Licensor:	  		  	
			
	BUSINESS CONTACT	  		  	
	Company:	  	             XipLink,
Inc

							
	Contact:	  	                 Jack
Waters
	  	Title:	  	
                    
                        CEO

							
	Address:	  	               3981
St. Laurent Bolvd, Suite 800

							
	City, State, Zip:	  	    Montreal, QC H2W
1Y5

							
	Telephone:	  	           (514) 848-9640 xt 234
	 	Fax:	  	
    (514) 848-964

							
	Email:	  	    jwaters©xiplink.com

  

							
	TECHNICAL CONTACT	  		  	
	Contact:	  	
                Thomas
Muller
	  	Title:	  	       Director of
Operations

							
	Address:	  	
              
(Same)

							
	City, State, Zip:	  	  

							
	Telephone:	  	             x230
	 	Fax:	 	  

							
	Email:	  	
tmuller@xiplink.com

 

							
	BILLING CONTACT (If different from above)

							
	Contact:	  	  Accounts Payable	  	Title:	  	 

							
	Address:	  	
            
(Same)

							
	City, State, Zip:	  	  

							
	Telephone:	  	
                    
                                
Fax:

							
	Email:	  	 ao@xiplink.com

					
	Purchase Order (if applicable):	  	     Licensee (Gogo) to pay premium.

 Note: Xiplink is not liable for premium but takes intellectual property deposit responsibility, 

 

							
	Licensee:
	
	BUSINESS CONTACT
	Company:	  	  
	  	Title:	  	  

							
	Contact:	  	  

							
	Address:	  	  

							
	City, State, Zip:	  	  

							
	Telephone:	  	  
	  	Fax:	  	  

							
	Email:	  	  

 

							
	TECHNICAL CONTACT

							
	Contact:	  	  
	  	Title:	  	  

							
	Address:	  	  

							
	City, State, Zip:	  	  

							
	Telephone:	  	  
	  	Fax:	  	  

							
	Email:	  	  

 

							
	BILLING CONTACT (If different from above)
	Contact:	  	  
	  	Title:	  	  

							
	Address:	  	  

							
	City, State, Zip:	  	  

							
	Telephone:	  	  
	  	Fax:	  	  

							
	Email:	  	  

							
	Purchase Order (if applicable):

  
 15 of 17

							
	Signed for and on behalf of XipLink, Inc.	 		 	
				
	Name:	 	  
	 		 	  

				
	Position	 	  
	 		 	(Authorized Signatory)
			
	Signed for and on behalf of Gogo LLC	 		 	
				
	Name:	 	  
	 		 	  

				
	Position	 	  
	 		 	(Authorized Signatory)
			
	Signed for and on behalf of NCC Group Escrow Associates, LLC	 		 	
				
	Name:	 	  
	 		 	  

				
	Position	 	  
	 		 	(Authorized Signatory)

  
 16 of 17

							
	Recipient:	  	© Escrow Associates 2012	  	 Date material
 received by
Escrow
 Agent:
	  	US Single-LEE

 Schedule 1 (Deposit Form) 
  

			
	 
ESCROW MATERIALS DEPOSIT FORM
	Escrow Account Number:	  	[Agreement Number]
	Product Name: XipLink XE Software	  	[Software Name] Release 4.0
	Date: February 1, 2013	  	 

 DEPOSITOR DETAILS 

							
	Company Name:	  	XipLink, Inc	  	Technical Contact:	  	(See Above)
	Address:	  	(See above)	  	Signature:	  	 
	 	  	 	  	Position:	  	 
	Telephone No:	  	 	  	Email Address:	  	 

 MATERIAL DETAILS 

									
	 Media Type
 (e.g. Disc, Tape etc.)
	  	 Number of media

items
	 	Name of Software	  	Version/Release
	DVD Media	  	1	 	XE–Release 4.0	  	4.0.0
	Hardcopy Documents (please supply details):	 	 	 	 	  	 
	Softcopy Documents (please give location on media, e.g.
ldocslbuild):	 	/Documents
	What Hardware was used to create the media deposit?	 	Apple Macbook
	What Operating System was used?	 	Mac OS X 10.6.8 or higher
	What Backup Command/Software was used?	 	tar
	What Software Compression has been used?	 	Gzip
	What Encryption/Password Protection has been used?	 	None
	In what Development Language is the source code written?	 	C/C++, Python, Unix Scripts
	Approximate size of the data on the media in megabytes?	 	200Mb
	Provide details of any third party software required to access/compile the
material.	 	Gcc under FreeBSD environment
	Provide details of any additional build information.	 	Will be provided under /Documents

 The following information MUST be provided for Escrow Agent to accept the deposit of escrow material: 

If this is your initial/first deposit, please fill in Section 1. 
 If this is your second or subsequent deposit (i.e. a replacement/update) please fill in Section 2. 
  

	
	 SECTION 1: Initial Deposit (First Deposit) – Is this a
complete deposit?
  ̈ YES     ̈ NO    if NO, please indicate when the rest of the deposit will be sent             

SECTION 2: Deposit Updates/Replacements – Is the deposit a complete replacement of any of the previous deposits?

 ̈ YES     ̈
NO
 If YES, would you like the past deposit(s) to be:
  ̈ RETAINED     ̈
RETURNED     ̈ DESTROYED                    *For returns and destroys, please
specify which deposit(s) this applies to by reference to the month and year of delivery to Escrow Agent
 (Tick ‘ALL’ if all previous
deposits):  ̈  All  ̈  SPECIFIC DEPOSIT(S):

  
 17 of 17

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00217-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00217-of-00352.parquet"}]]