Document:

QuickLinks
 -- Click here to rapidly navigate through this document
  

Exhibit 10.1  

 
 

PURCHASE & RESERVATION AGREEMENT  
  

        THIS PURCHASE & RESERVATION AGREEMENT (this "Agreement"), is dated as of June 4,
2007 (the "Effective Date"), by and between Edison Mission Energy, a Delaware corporation, having its principal place of business at 18101 Von Karman Avenue, Suite 1700, Irvine, California 92612
("Owner"), and Suzlon Wind Energy Corporation, a Delaware corporation, having its principal place of business at 7th Floor, 8750 West Bryn Mawr Avenue, Chicago, Illinois 60631
("Suzlon"), sometimes collectively referred to as the "Parties" or singularly as a "Party." 

W I T N E S S E T H:  

        WHEREAS, Suzlon is a manufacturer and supplier of wind turbine generators and related services and equipment; 

        WHEREAS, Owner desires to purchase and Suzlon agrees to design and manufacture, or cause to be designed and manufactured, and sell to
Owner certain WTGs; 

        WHEREAS, Suzlon shall also deliver and Commission, (and Owner shall purchase) the WTGs in accordance with the terms and provisions of this
Agreement; and 

        NOW, THEREFORE, in consideration of the mutual covenants herein contained and other good and valuable consideration, the receipt and
sufficiency of which are hereby acknowledged, the Parties hereto, intending to be legally bound, hereby agree as follows: 

ARTICLE 1  

 DEFINITIONS  

        1.1    Defined
Terms.    For purposes of this Agreement, the following terms shall have the following definitions: 

        "2008
Contract Price" has the meaning given in Section 3.1(a) of this Agreement. 

        "2008
Extended Delivery WTGs" means those 2008 WTGs with a Delivery Deadline occurring in *** of 2008. The Parties acknowledge and agree that the number of 2008 WTGs with a Delivery
Deadline occurring in *** of 2008, collectively, shall not exceed *** (***), excluding any WTGs whose Delivery Deadline is deferred to a date in *** of 2008 as a result of Force Majeure, a request by
Owner to Deliver such WTGs' components which are manufactured outside the continental United States to an Alternate Port, or any other provision in this Agreement pursuant to which Suzlon is entitled
to an adjustment in the Delivery Deadline as to such WTGs. Suzlon acknowledges and agrees that it shall use reasonable efforts to minimize the number of 2008 WTGs that are Extended Delivery WTGs, but
Suzlon's failure to reduce the number of 2008 Extended Delivery WTGs below the aforementioned number shall not be 

1

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

deemed
a Suzlon Default or a default under this Agreement and Suzlon shall have no liability to Owner for any such failure. 

        "2008
GL Liquidated Damages" has the meaning given in Section 2.6(b)(i) of this Agreement. 

        "2008
PTC LD Cap" means an amount equal to *** percent (***%) of the Total 2008 Contract Price. 

        "2008
WTGs" has the meaning given in Section 2.1(a) of this Agreement. 

        "2009
Contract Price" has the meaning given in Section 3.1(b) of this Agreement. 

        "2009
GL Liquidated Damages" has the meaning given in Section 2.6(b)(ii) of this Agreement. 

        "2009
PTC LD Cap" means an amount equal to *** percent (***%) of the Total 2009 Contract Price. 

        "2009
WTGs" has the meaning given in Section 2.1(b) of this Agreement. 

        "Acceptable
Replacement Security" means (i) a guarantee of a Person with comparable creditworthiness to Edison Mission Energy as of the Effective Date whereby such Person
guarantees the obligations of the Owner under this Agreement (provided such guarantee is in a form substantially similar to the Owner Parent Guarantee), or (ii) other equivalent credit support
in form and substance reasonably acceptable to Suzlon. 

        "Additional
TA Fees" has the meaning given in Section 3.1(d) of this Agreement. 

        "Affiliate"
means, as to a specified Person, any other Person that, directly or indirectly through one or more intermediaries, controls or is controlled by or is under common control
with the Person specified. 

        "Aggregate
LD Cap" has the meaning given in Section 5.1(b) of this Agreement. 

        "Aggregate
TA Hours" has the meaning given in Section 3.1(d) of this Agreement. 

        "Agreement"
has, subject to the terms of Section 11.14, the meaning given in the Preamble to this Agreement. 

        "Alternate
Final Milestone" has the meaning given in Section 3.2(a) or Section 4.1(b) of this Agreement, as applicable. 

        "Alternate
Port" means a port (other than a Gulf Port) designated by Owner pursuant to the terms and conditions of this Agreement; provided, however, that such port (a) shall be
capable of accepting the delivery of WTG components thereto, which shall include, without limitation having adequate capabilities for receiving Suzlon's shipping vessels and inland transportation
vehicles (if applicable) and sufficient berthing, offloading, management and 

2

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

storage
capabilities for Suzlon to perform its obligations pursuant to this Agreement, and (b) shall be located in (i) the continental United States (as to Projects located in the
continental United States), or (ii) the continental United States or the mainland of Canada (as to Canadian Projects). 

        "Alternate
Power Plant" has the meaning given in Section 2.5(d) of this Agreement. 

        "Applicable
Date" means (x) December 31, 2007, in the event there is an Applicable Wind Farm as of December 1, 2007, or (y) in the event there is not yet an
Applicable Wind Farm as of December 1, 2007, the date that is one (1) month after the date there is an Applicable Wind Farm. 

        "Applicable
SC-Power Plant" has the meaning given in Section 2.5(d) of this Agreement. 

        "Applicable
Wind Farm" means any "Project" (as defined in that certain Purchase & Reservation Agreement, by and between Owner and Suzlon, dated as of November 15, 2005, as
amended, or any "Definitive Agreement" executed thereunder (as applicable)) that has (i) achieved "Commissioning" of a substantial portion of its (but in no event less than ten (10)) "WTGs"
(each as defined in such applicable agreement), (ii) whose "owner" has, no later than ***, (x) requested in writing the SC-Power Plant, and (y) actually paid Suzlon
the fee for such SC-Power Plant, and (iii) whose Owner has such "Project" reasonably ready for the installation of the SC-Power Plant. 

        "Application
for Payment" has the meaning given in Section 3.4(a) of this Agreement. 

        "Available
Milestone Amount" means, with respect to each Milestone Payment, an amount equal to (i) the total amount of such Milestone Payment, less (ii) amounts from such
Milestone Payment that will be deposited in a Payment Escrow pursuant to Section 11.7(b). 

        "Availability
Warranty" has the meaning given in Exhibit G to this Agreement. 

        "Balance
of Plant" means all equipment and materials and other items and services necessary to complete a Project in accordance with prudent electric industry practices for wind
generation projects of a similar nature, except for the corresponding Work. The Balance of Plant includes, but is not limited to, the following items, which, as between Owner and Suzlon, Owner shall
provide: 

	(i)
	all
geotechnical studies, investigations and site and other surveys;

	(ii)
	demolition
and/or removal, to the extent necessary, of any existing facilities at a Project Site;

	(iii)
	grading,
trenching, excavation and other preparation of a Project Site;

	(iv)
	the
civil engineering, construction and testing of all civil works (including that which is related to the WTG foundations); 

3

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

	(v)
	permits
(other than those set forth in Section 2.5 of the Definitive Agreements or Section 2.2 of the Modified Obligations (as the case may be));

	(vi)
	design,
engineering, procurement, installation, grading and construction of crane pads at the WTG sites, access roads to the WTGs (including, but not limited to, any modifications
and/or upgrades to public or other roads which are necessary for the transportation of the WTGs to the Project Site), lay down areas for the WTGs (as well as for storage and tools) and staging areas
for delivery;

	(vii)
	FAA
warning lights, meteorological stations and foundations (including those for the transformers, met masts and WTGs);

	(viii)
	anchor
bolts with nuts and washers, specification of torque settings for foundation bolts and grouting and tensioning of anchor bolts;

	(ix)
	design,
engineering, procurement, installation and construction of cable and pipe ducting, all interconnection facilities (including the padmount transformers and the padmount
switchgear), the communications system and the communications system cables and interface hardware, the kV electrical collection system and substation, the electrical works (whether above ground or
below ground) and the control works (including installation, supply and termination of 600V electrical cables between ground bus panel and pad transformer);

	(x)
	design,
installation and termination of grounding system to the towers, switchgear, transformers, pad transformers, grid interconnects and the Project substation;

	(xi)
	supply
of met masts required for any power curve testing;

	(xii)
	installation
and supply of fiber-optic cabling between the WTGs;

	(xiii)
	high
speed internet access;

	(xiv)
	sanitary
facilities for Suzlon's non-exclusive use;

	(xv)
	connecting
a Project to the transmission grid (including, without limitation, all interconnection facilities);

	(xvi)
	energizing
a Project;

	(xvii)
	connecting
power to the base bus bar in the control panel;

	(xviii)
	work
space in temporary construction trailers, offices or similar facilities for Suzlon's non-exclusive use during Suzlon's Commissioning of the WTGs; and

	(xix)
	all
items listed on Exhibit I to this Agreement as being within Owner's scope. 

4

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

        "Bill
of Lading/Ex Works Milestone Payment" has the meaning given in Section 3.2(a) or Section 4.1(b) (as the case may be) of this Agreement. 

        "Blades"
has the meaning given in the definition of the term WTG. 

        "Business
Day" means any day other than a Saturday or Sunday or a day on which commercial banks are closed in the State of Illinois. 

        "Canadian
Project" means a Project located in the mainland of Canada consisting of at least twenty-four (24) WTGs; provided, however, that such Project shall be
located (a) in the Canadian provinces of Manitoba or Ontario, or, in the event the PTC Qualification Date is not extended to December 31, 2009 or any date thereafter, the Canadian
provinces of Manitoba, Ontario, Alberta or Saskatchewan, and (b) within fifty (50) kilometers of a municipality with a permanent population of greater than ten thousand (10,000).
Notwithstanding the foregoing or anything to the contrary contained in this Agreement, Suzlon shall not be responsible for compliance with any Canadian Law requiring that a minimum percentage of
content of goods used in a Canadian Project be produced or manufactured in Canada (or any other designated location), and shall have no liability to Owner or any of its Affiliates for the failure of a
Canadian Project to comply with the same. 

        "Cancellation
Fee" has the meaning given in Section 8.5(b) of this Agreement. 

        "Cancelled
Amount" has the meaning given in Section 8.5(a) of this Agreement. 

        "Certificate
for Payment" has the meaning given in Section 3.4(b) of this Agreement. 

        "Certificate
of Commissioning" has the meaning given in Section 2.2(i) to this Agreement. 

        "Certificate
of Final Completion" has the meaning given in Section 2.2(l) of this Agreement. 

        "Certificate
of Mechanical Completion" has the meaning given in Exhibit O to this Agreement. 

        "Change
in Law" shall mean and refer to the enactment, adoption, promulgation, amendment, modification, repeal or change in interpretation by a Governmental Authority after the Effective
Date of any Law which is applicable to the performance of the Work. 

        "Climb-Assist
Election" has the meaning given in Section 3.2(f) of this Agreement. 

        "Climb-Assist
Election Deadline" means (i) as to the 2008 WTGs, the date that is one (1) month after the Effective Date, and (ii) as to the 2009 WTGs, May 1,
2008. 

        "Climb-Assist
Fee" means *** U.S. Dollars ($***) for each WTG containing the Climb-Assist System; which fee, if applicable, shall be in addition to the Contract Price. 

5

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

        "Climb-Assist
System" means that "climb-lift assist" (Tuf Tug model) system as further described in Exhibit S to this Agreement. 

        "Commission(ing)"
means the start-up and commissioning activities to be performed by Suzlon in accordance with the Commissioning Test and Inspection Procedures, including the
production of positive power (unless a WTG is unable to produce positive power as a result of any event, failure or circumstance other than Suzlon's failure to perform its obligations under this
Agreement). 

        "Commissioning
Date" means, with respect to each Project, the earlier of (i) the date that the actual physical Commissioning of the first WTG at a Project is complete, or
(ii) the date which is sixty (60) days after the date that the first WTG for such Project is Delivered. 

        "Commissioning
Deadline", as to each WTG, means the date which is *** (***) days after the later of (a) the date the Certificate of Mechanical Completion corresponding to such WTG
is executed by both Parties, (b) the Deferral Date (but only if a WTG is an Excess WTG), (c) as to any Second Notice WTG, the date which is *** (***) days after the date Owner delivers
to Suzlon a Second Expected Mechanical Completion Notice as to such WTG (or, in the event Owner does not deliver to Suzlon a Second Expected Mechanical Completion Notice as to such WTG, the date that
is *** (***)
days after the date of the Certificate of Mechanical Completion corresponding to such WTG), and (d) *** (in the event such WTG is a 2008 Extended WTG); each as such dates may be extended
pursuant to the terms and conditions of this Agreement (including, without limitation, the terms of Section 11.15(a)). 

        "Commissioning
LD Cap" means (i) for a 2008 WTG, an amount equal to *** percent (***%) of its 2008 Contract Price or (ii) for a 2009 WTG, an amount equal to *** percent
(***%) of its 2009 Contract Price. 

        "Commissioning
Liquidated Damages" has the meaning given in Section 2.2(h) of this Agreement. 

        "Commissioning
Test and Inspection Procedures" shall mean those tests and procedures as set forth in Schedule C of Exhibit G of this Agreement, which Commissioning Test and
Inspection Procedures may be updated from time to time by Suzlon by written notice to Owner, provided that such update may not modify the terms of this Agreement. 

        "Competitor"
means any Person that designs and/or manufactures wind turbine generators. 

        "Confidential
Information" has the meaning given in Section 10.1(a) of this Agreement. 

        "Contract
Price" has the meaning given in Section 3.1(c) of this Agreement. 

        "Control"
means, with respect to a Person, the power, directly or indirectly, to direct, determine, manage, control (or cause the direction of) the management, business, operations,
activities, investments or policies of such Person, whether through the ownership of any interest (directly or indirectly) in such Person, by contract or otherwise. 

6

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

        "Controller"
has the meaning given in the definition of the term WTG. 

        "Day"
or "day" shall mean and refer to a calendar day. 

        "Deadline
Dates" shall mean and refer to the Delivery Deadline and the Commissioning Deadline. 

        "Deferral
Date" has the meaning given in Section 2.2(k) of this Agreement. 

        "Definitive
Agreements" means, as the context dictates, either (i) the TSIA and WMSA, or (ii) the TSA and WMSA. 

        "Deliver",
"Delivery" or "Delivered" shall mean that the applicable WTG has been delivered to (or, as applicable, made available "ex works" at) the Initial Delivery Point. 

        "Delivery
Deadline" means (i) as to each 2008 WTG, the last day of the calendar month to which such WTG applies pursuant to the Delivery Schedule, and (ii) as to each 2009
WTG, the last day of the calendar month to which such WTG applies pursuant to the Delivery Schedule (as such deadlines may be adjusted pursuant to the terms and conditions of this Agreement). 

        "Delivery
LD Cap" means (i) for a 2008 WTG, an amount equal to *** percent (***%) of its 2008 Contract Price or (ii) for a 2009 WTG, an amount equal to *** percent (***%)
of its 2009 Contract Price. 

        "Delivery
Liquidated Damages" has the meaning given in Section 2.1(f)(i) of this Agreement. 

        "Delivery
Schedule" has the meaning given in Section 2.1(e) of this Agreement. 

        "Design
Materials" has the meaning given in Exhibit G to this Agreement. 

        "Effective
Date" has the meaning given in the Preamble to this Agreement. 

        "Estimate
Notice" means a notice (i) that requests a cost estimate from Suzlon for the Delivery of the WTGs to an Alternate Port in lieu of a Gulf Port (if applicable), delivery
of the WTGs from the Initial Delivery Point to a Project Site, installation and achievement of Mechanical Completion of such WTGs at such Project Site, (ii) that includes the following:
identification of the Alternate Port (if applicable), the specific Project Site, a proposed project schedule, a site plan that includes the proposed layout/location of the WTGs, identification of all
existing and proposed access and service roads, a topographical survey, and identification of all potential physical impediments to the delivery and Mechanical Completion of the WTGs (such as existing
overhead lines, difficult terrain, site conditions, etc.), and (iii) that grants Suzlon and its representatives access to a Project Site for inspection of the same. 

        "Excess
WTGs" has the meaning given in the definition of Seven Day Event; provided, however, that a WTG shall cease to be an Excess WTG upon the occurrence of the Deferral Date for such
Excess WTG. 

7

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

        "Expected
MC Date" has the meaning given in Section 2.2(c)(ii) of this Agreement. 

        "Expected
Mechanical Completion Notice" has the meaning given in Section 2.2(c)(i) of this Agreement. 

        "FERC"
means the United States Federal Energy Regulatory Commission. 

        "Final
Completion" means, with respect to each Project, Suzlon has performed in accordance with this Agreement with respect to such Project, Commissioning of the WTGs at such Project has
been achieved, and all items on the Punch List for such Project have been completed. 

        "Final
Payment" has the meaning given in Section 3.2(a) or Section 4.1(b) of this Agreement, as applicable. 

        "Force
Majeure" means an event or events the cause of which is beyond the control of, and does not in any way result from the fault or negligence of, the Party claiming its performance
is affected and which, by the exercise of due diligence and foresight, could not have been avoided including, but not limited to, any acts of war, sabotage, terrorism, rebellion, insurrection, acts of
foreign enemies, any Change in Law, military or usurped power or martial law, expropriation or confiscation of facilities or property by order of any Governmental Authority, any act or, failure to act
by any Governmental Authority purporting to exercise jurisdiction which prevents or delays performance (other than acts or omissions of the affected Party), fires, floods, explosions, hail, unusually
severe ice and ice storms, earthquakes, unforeseeable site conditions, other Acts of God, perils of sea, any strikes, lockouts or other labor disputes affecting such Party or any of its suppliers and
subcontractors, winds in excess of ten (10) meters/second during Mechanical Completion, ten (10) meters/second during Commissioning and twenty (20) meters/second during service
and maintenance (or such other restriction as may be imposed by applicable Laws), and any delay or interference by the other Party or its contractors or subcontractors. As to Suzlon, the term "Force
Majeure" shall also include (a) any delay in performance caused by the failure of the Balance of Plant to be properly and timely installed, and (b) any extension in any Mechanical
Completion Deadline pursuant to Section 11.15(b). 

        "Force
Majeure Work" has the meaning given in Exhibit G to this Agreement. 

        "Fourth
2009 Milestone Payment" has the meaning given in Section 3.2(a) or Section 4.1(b) (as the case may be) of this Agreement. 

        "Full
Power Plant" has the meaning given in Section 2.5(d) of this Agreement. 

        "Full
PP Holdback" has the meaning given in Section 2.5(d) of this Agreement. 

        "Full
PP Test Procedures" means testing protocols to be agreed by the Parties in writing as soon as reasonably possible after the Effective Date, which testing protocols shall detail
steps to confirm the Applicable SC-Power Plant's (or, as applicable, Alternate Power Plant's) ability (i) to curtail and regulate the active power output from the wind farm being
tested, (ii) to start and stop such wind farm, (iii) to regulate the power factor at the interconnection point according to a received set point, (iv) to monitor, control and
receive information for a number of 

8

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

communication
interfaces, and (v) to have the full functionality and ability to perform; each in accordance with the applicable portions of the SC-Power Plant specifications
attached hereto as Exhibit N. Further, any test of an Applicable SC-Power Plant pursuant to the Full PP Test Procedures shall not be deemed successfully performed if the associated
test results indicate that the SC-Power Plant is not capable of being installed and successfully tested at other "Projects" (as defined in that certain Purchase & Reservation
Agreement, by and between Owner and Suzlon, dated as of November 15, 2005, as amended, or any "Definitive Agreement" executed thereunder (as applicable)). 

        "Germanischer
Lloyd Type Certificate" means, at Suzlon's option, either (i) a "type certificate" issued by Germanischer Lloyd for the low temperature version of the WTGs, or
(ii) a "type certificate" issued by Germanischer Lloyd for the standard temperature version of the WTGs, along with an amendment to such certificate issued by Det Norske Veritas that covers the
low temperature aspects of the WTGs, which shall be substantially similar to the applicable form(s) attached hereto as Exhibit R. Upon receipt of an unconditional Germanischer Lloyd Type
Certificate, such actual certificate shall automatically replace the forms included as Exhibit R and shall be made a part of this Agreement. 

        "GL
Liquidated Damages" has the meaning given in Section 2.6(b)(ii) of this Agreement. 

        "Governmental
Authority" shall mean and refer to any national, federal, state, county, municipal or local government, agency, authority or court, or any department, board, bureau or
instrumentality thereof. 

        "Gulf
Port" means any port selected by Suzlon, in its sole discretion, which is located on or along the Gulf of Mexico in the States of Texas or Louisiana. 

        "Hub"
has the meaning given in the definition of the term WTG. 

        "IDP
Fee" has the meaning given in Section 3.2(d)(ii) of this Agreement. 

        "Included
SCADA" means the "SC-Commander (software)", "SC-SCADA Reporting", and "SC-Turbine", all as more particularly described in the Technical
Specifications. 

        "Initial
Delivery Point" means 

        (a)   As
to any component of a WTG which is manufactured outside the continental United States, the "clearing" of such component through United States customs at a Gulf Port
(or, if applicable, any Alternate Port), and its delivery to the first place of rest at the temporary storage location at such port (or nearby if such location is designated by the port authority to
be an area external to the port) where the WTG component will be made available for inland transportation to a Project Site; and 

        (b)   As
to any component of a WTG which is manufactured within the continental United States, the availability of such component "ex works" the manufacturer's plant. 

        "Installation
Manual" has the meaning given in Exhibit G to this Agreement. 

9

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

        "Interest
Rate" means an annual interest rate which is the lesser of (i) nine percent (9%), or (ii) the maximum interest rate permitted by law. 

        "Installation
Contractor" means, if any, an Owner's Contractor retained by Owner to perform Owner's obligations relating to installation and achievement of Mechanical Completion of the
WTGs. 

        "IPR
Liability" has the meaning given in Section 5.2 of this Agreement. 

        "Law"
means any constitution, charter, statute, treaty, act, law, ordinance, regulation, code, rule, order, decree, permit, judgment, directive, ruling, decision, order, guideline,
resolution or declaration of any Governmental Authority, or any interpretation or application thereof by any such Governmental Authority. 

        "Liability
Cap" has the meaning given in Section 5.2 of this Agreement. 

        "Losses"
has the meaning given in Section 5.2 of this Agreement. 

        "Lost
Purchase Price" has the meaning given in Section 8.5(d)(ii) of this Agreement. 

        "LVRT
Fee" has the meaning given in Section 3.2(e) of this Agreement. 

        "LVRT
System" means, with respect to a WTG, a system that allows such WTG, following an electrical transition period, to remain connected to the electrical transmission grid as required
under FERC Order No. 661-A. 

        "Maintenance
Work" has the meaning given in Exhibit G to this Agreement. 

        "Major
Components" means the Tower, the Nacelle, the Hub, the Blades, the Controller, and the Turbine Generator of each WTG. 

        "Measured
Average Availability Liquidated Damages" has the meaning given in Exhibit G to this Agreement. 

        "Mechanical
Completion" or "Mechanically Complete" shall be deemed to have occurred as to each WTG when such WTG has been assembled, completely installed and erected in accordance with
the Installation Manual and otherwise satisfies the criteria in the Mechanical Completion Checklist. 

        "Mechanical
Completion Checklist" means collectively the "Installation Manual, Check List Mechanical Completion" and the "Check List, Electrical Installation Manual" utilized in relation
to determining whether Mechanical Completion of a WTG has been achieved, all as set forth in Exhibit K of this Agreement. 

        "Mechanical
Completion Date" has the meaning given it in Exhibit O. 

        "Mechanical
Completion Deadline" has the meaning given in Section 2.2(c) of this Agreement. 

10

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

   
        "Mechanical Completion Notice Deadline" means (i) as to the 2008 WTGs (other than the 2008 Extended Delivery WTGs and 2008 WTGs with a Delivery Deadline in ***), ***,
(ii) as to 2008 WTGs with a Delivery Deadline in ***, ***, (iii) as to the 2008 Extended Delivery WTGs, ***, and (iv) as to the 2009 WTGs, ***; provided, however, for any Project
consisting of more than sixty (60) WTGs, the Mechanical Completion Notice Deadline for such WTGs shall be "x" days earlier than the date listed in clause (i) or (ii) above (as
applicable), with "x" equal to (a) two (2), multiplied by (b) the total number of WTGs at such Project over sixty (60) such WTGs. 

        "Mechanical
Completion Process" means the process utilized in relation to determining whether Mechanical Completion of a WTG has been achieved, all as set forth in Exhibit O of
this Agreement. 

        "Milestone(s)"
has the meaning given in Section 3.2(a) of this Agreement. 

        "Milestone
Payment" has the meaning given in Section 3.2(a) of this Agreement. 

        "Modified
Obligations" has the meaning given in Section 4.1 of this Agreement. 

        "Nacelle"
has the meaning given in the definition of the term WTG. 

        "Notice
of Mechanical Completion" has the meaning given in Exhibit O of this Agreement. 

        "NTP(s)"
has the meaning given in Section 2.3(a) of this Agreement. 

        "Operation
Manual" has the meaning given in Exhibit G to this Agreement. 

        "Optional
SCADA" means the SC-Power Plant, "SC-Met Station" and the hardware to run the "SC-Commander (software)" (as more particularly described on
Exhibit N hereto), as well as any other changes to the supervisory control and acquisition system agreed upon by the Parties in writing. 

        "Outside
Mechanical Completion Deadline" means, as to each WTG, the date which is the *** (***) anniversary of the date each such WTG has been Delivered. 

        "Owner"
means the named Owner identified in the Preamble to this Agreement and its successors and permitted assigns. 

        "Owner
Default" has the meaning given in Section 8.3 of this Agreement. 

        "Owner
Guarantor" has the meaning given in Section 11.7(c)(i) of this Agreement. 

        "Owner's
L/C" has the meaning given in Section 11.7(c)(ii) of this Agreement. 

        "Owner
Parent Guarantee" has the meaning given in Section 11.7(c)(i) of this Agreement. 

11

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

        "Owner's
Contractor" shall mean any contractor, subcontractor or consultant retained by Owner to perform any of Owner's obligations or responsibilities (including, without limitation,
construction of a Project's Balance of Plant). 

        "Party"
or "Parties" has the meaning given in the preamble to this Agreement. 

        "Payment
Escrow" has the meaning given in Section 11.7(b) of this Agreement. 

        "Performance
Holdbacks" means the V3 Holdback, the Preliminary PP Holdback and the Full PP Holdback. 

        "Performance
Side Letter" means that certain Performance Side Letter Agreement by and between Owner and Suzlon, dated as of the date hereof. 

        "Person"
means any individual, corporation (including a business trust), partnership, limited liability company, association, joint stock company, trust, unincorporated organization,
joint venture, Governmental Authority, or any other entity. 

        "Power
Curve Guarantee" has the meaning given in Exhibit G to this Agreement. 

        "Power
Curve Liquidated Damages" has the meaning given in Exhibit G to this Agreement. 

        "Preliminary
Power Plant" has the meaning given in Section 2.5(c) of this Agreement. 

        "Preliminary
PP Holdback" has the meaning given in Section 2.5(c) of this Agreement. 

        "Preliminary
PP Test Procedures" means testing protocols to be agreed by the Parties in writing as soon as reasonably possible after the Effective Date, which testing protocols shall
detail steps to confirm the Preliminary Power Plant's ability (i) to curtail and regulate the active power output from the wind farm being tested, and (ii) to start and stop such wind
farm; each in accordance with the applicable portions of the SC-Power Plant specifications attached hereto as Exhibit N. 

        "Price
Estimate" has the meaning given in Section 2.3(g) of this Agreement. 

        "Project"
means the WTGs and the Balance of Plant for a Project Site. 

        "Project
Site(s)" means the project site(s) described in NTPs issued by Owner (provided, however, if Owner fails to timely issue an NTP as to any WTG(s), the Owner shall in any event
notify Suzlon of the project site for such WTG(s) promptly after Owner is aware of the same). All Project Sites must be located in the continental United States or Canada, provided, however, all
Projects Sites in Canada must meet the requirements listed in the definition of "Canadian Projects". 

        "PTCs"
means the renewable electricity production credits available under 26 U.S.C. § 45. 

12

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

        "PTC
LD Amount" means (i) an amount equal to *** U.S. Dollars ($***) for each 2008 WTG, and (ii) an amount equal to *** U.S. Dollars ($***) for each 2009 WTG; provided,
however, that such amounts shall be equitably adjusted to reflect any modification of, or amendment to, 26 U.S.C. § 45 that occurs after the Effective Date and (a) lengthens or
shortens the ten (10) year benefit period provided therein, (b) increases or decreases the base kilowatt-hour rate of $0.015 provided therein, or (c) otherwise
materially alters the economic benefit provided by the PTCs. 

        "PTC
Liquidated Damages" has the meaning given in Section 2.2(j) of this Agreement. 

        "PTC
Qualification Date" means the date by which a WTG for a Project must be placed into service, as defined by 26 U.S.C. § 45 as amended from time to time and related
regulations, in order to be eligible to receive PTCs. It is acknowledged by the Parties that the PTC Qualification Date as of the Effective Date is December 31, 2008. 

        "Punch
List" means, as to any Project, the comprehensive list mutually prepared by Owner and Suzlon upon Commissioning of the last WTG of such Project, identifying those details of
construction and mechanical adjustment with respect to Suzlon's Work which require repair, completion, correction or re-execution by Suzlon. 

        "Punch
List Holdback" has the meaning given in Section 3.4(e) of this Agreement. 

        "Remarketing
Costs" has the meaning given in Section 8.5(d)(ii) of this Agreement. 

        "Reimbursable
Expenses" has the meaning given in Section 3.2(d) of this Agreement. 

        "Reservation
Payment" has the meaning given in Section 3.2(a) of this Agreement. 

        "Retention"
has the meaning given in Section 11.7(b) of this Agreement. 

        "SC-Power
Plant" means the supervisory control and data acquisition system power plant as more particularly described on Exhibit N hereto. 

        "Scheduled
Maintenance" has the meaning given in Exhibit G to this Agreement. 

        "Second
Expected Mechanical Completion Notice" has the meaning given in Section 2.2(c)(ii) of this Agreement. 

        "Second
Notice WTGs" has the meaning given in Section 2.2(c)(ii) of this Agreement. 

        "Security
Milestone Payment" has the meaning given in Section 11.7(b) of this Agreement. 

        "Seven
Day Event" means the achievement during any seven (7) day period of either (a) Mechanical Completion of more than fifteen (15) WTGs, or (b) Mechanical
Completion of fifteen (15) or fewer WTGs at more than three (3) Project Sites (provided, however, that solely for the purposes of the calculation in this
sub-clause (b) and sub-clause (y) below, Project Sites that are located within a five (5) mile radius of each other shall be considered a single Project 

13

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

Site).
For purposes of this Agreement, "Excess WTGs" means (x) those WTGs in excess of fifteen (15) upon the occurrence of the event described in clause (a) of the preceding
sentence, or (y) all WTGs in clause (b) of the preceding sentence, excluding those WTGs at the three (3) Project Sites with the greatest number of WTGs which were Mechanically
Completed during such seven (7) day period. 

        "Side
Letter Holdback" means a holdback made pursuant to the terms of the Performance Side Letter. 

        "Sleeping
Bear Wind Farm" means the "Project Site" as defined in that certain Turbine Supply Agreement to be entered into by and between Sleeping Bear, LLC and Suzlon. 

        "Sourcing
Determination" has the meaning given in Section 2.1(m) of this Agreement. 

        "Specified
Information" has the meaning given in Section 10.1(b) of this Agreement. 

        "Standby
Fee" has the meaning given in Section 2.2(c)(ii) of this Agreement. 

        "Successful
V3 Test" has the meaning given in Section 2.5(b) of this Agreement. 

        "Suzlon"
means Suzlon Wind Energy Corporation and its successors and permitted assigns. 

        "Suzlon
Default" has the meaning given in Section 8.1 of this Agreement. 

        "Suzlon
Guarantor" has the meaning given in Section 11.7(a) of this Agreement. 

        "Suzlon
L/C" has the meaning given in Section 11.7(b) of this Agreement. 

        "Suzlon
Parent Guarantee" has the meaning given in Section 11.7(a) of this Agreement. 

        "Suzlon
Security" has the meaning given in Section 11.7(b) of this Agreement. 

        "Suzlon
Storage Days" means (x) the number of days a WTG or any WTG component is in storage or is otherwise unable to be transported or installed at a Project Site primarily as a
result of Suzlon's need to perform corrective action with respect to a defect or deficiency in the same or (y) if such WTG or WTG component was in storage or is otherwise unable to be
transported or installed at a Project Site for reasons other than primarily as a result of Suzlon's need to perform corrective action with respect to a defect or deficiency in the same, but the amount
of time such WTGs or WTG components remained in storage or is otherwise unable to be transported or installed at a Project Site was extended primarily as a result of Suzlon's need to perform
corrective action with respect to a defect or deficiency in the same, the number of days by which such storage or inability to be transported or installed at a Project Site was extended. 

        "TA
Request" has the meaning given in Section 3.1(d) of this Agreement. 

        "Taxes"
means any and all United States and Canadian federal, state, municipal or local governmental taxes, duties, levies or tariffs related to, or incurred in connection with, the 

14

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

performance
of the Work (including, without limitation, all United States and Canadian federal, state, municipal or local governmental sales, use, excise, property and real estate taxes and, for the
sake of clarity, Canadian import taxes and import duties in the case of any Canadian Project), but excluding any United States import taxes and import duties. 

        "Technical
Specifications" has the meaning given in Exhibit G to this Agreement. 

        "Third
2008 Milestone Payment" has the meaning given in Section 3.2(a) or Section 4.1(b) (as the case may be) of this Agreement. 

        "Third
2009 Milestone Payment" has the meaning given in Section 3.2(a) or Section 4.1(b) (as the case may be) of this Agreement. 

        "Threshold
Date" has the meaning given in Section 2.5(d) of this Agreement. 

        "Total
2008 Contract Price" has the meaning given in Section 3.1(c) of this Agreement. 

        "Total
2009 Contract Price" has the meaning given in Section 3.1(c) of this Agreement. 

        "Tower"
has the meaning given in the definition of the term WTG. 

        "TSA"
means Turbine Supply Agreement in the form attached hereto as Exhibit A-1. 

        "TSIA"
means Turbine Supply and Installation Agreement in the form attached hereto as Exhibit A-2. 

        "Turbine
Generator" has the meaning given in the definition of the term WTG. 

        "V3
Holdback" has the meaning given in Section 2.5(b) of this Agreement. 

        "V3
Liquidated Damages" has the meaning given in Section 2.5(b) of this Agreement. 

        "V3
Liquidated Damages Share" has the meaning given in Exhibit G to this Agreement. 

        "Warranty
Service" has the meaning given in Exhibit G to this Agreement. 

        "WMSA"
means the Warranty, Maintenance and Services Agreement in the form attached hereto as Exhibit A-3. 

        "Work"
means all work, services, equipment and items necessary to design, manufacture, deliver and Commission the WTGs in accordance with the terms and provisions of this Agreement,
including all items listed on Exhibit I to this Agreement as being within Suzlon's scope. 

        "WTG(s)"
means those certain model number S-88/2.1 MW wind turbine generators, "Low Temperature Version", with a hub height of 79 meters; each of which is comprised of: a
complete tower, including internal ladders and platforms (a "Tower"), a turbine generator nacelle (a "Nacelle"), the component at which the rotor blades are attached to the drive shaft of the wind
turbine (a "Hub"), a matched set of three (3) separate V3 rotor blades or other comparable blades 

15

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

as
Suzlon may then be manufacturing for the S-88 model (each such matched set of three, "Blades"), the control panels (the "Controller") and a turbine generator to be located within the
Nacelle (a "Turbine Generator"), all as more particularly described in the Technical Specifications. As used in this Agreement and where the context so requires, the term WTG(s) shall mean the 2008
WTG(s) and/or the 2009 WTG(s). 

ARTICLE 2  

 SALE & PURCHASE OF WTGS  

        2.1    WTG.    (a)    In
accordance with the terms of this Agreement, Suzlon hereby agrees to design,
manufacture, deliver, Commission and sell to Owner, and Owner hereby agrees to purchase from Suzlon, one hundred fifty (150) WTGs for delivery and, subject to the terms of this Agreement,
Commissioning, during the calendar year of 2008 (the "2008 WTGs"). The Parties acknowledge and agree that, for purposes of this Agreement (except as otherwise expressly provided
in the definition of "Mechanical Completion Notice Deadline" and Sections 2.2(j)(iii), 2.3(a), 2.3(b), and 8.5(b) of this Agreement), the term "2008 WTGs" shall include the 2008 Extended Delivery WTGs
notwithstanding the Commissioning of any 2008 Extended Delivery WTGs during the calendar year of 2009. 

        (b)   Additionally,
in accordance with the terms of this Agreement, Suzlon hereby agrees to design, manufacture, deliver, Commission and sell to Owner, and Owner hereby agrees
to purchase from Suzlon, one hundred fifty (150) WTGs for delivery and, subject to the terms of this Agreement, Commissioning, during the calendar year of 2009 (the "2009 WTGs"). 

        (c)   Except
as otherwise expressly provided in this Agreement, the Parties' obligations as to the sale, purchase, design, manufacture, delivery and Commissioning of the WTGs
shall constitute the legally valid and binding obligations of the parties, on and subject to the terms of this Agreement. 

        (d)   Owner
acknowledges and agrees that the WTGs to be supplied under this Agreement, as well as under the Definitive Agreements, shall be "Low Temperature Versions". 

        (e)   Attached
hereto as Exhibit B is a schedule ("Delivery Schedule") which identifies the calendar months of 2008 and 2009 during which each WTG shall be Delivered.
If, pursuant to the issuance of an NTP, Owner requests that any WTG components which are manufactured outside the continental United States be Delivered to an Alternate Port, the Parties shall
promptly thereafter equitably adjust (by amendment to this Agreement) the Delivery Schedule and the Deadline Dates to reflect the schedule impact to Suzlon resulting from such request by Owner. Owner
shall be responsible for the increased costs of Delivery to an Alternate Port (in lieu of a Gulf Port, if applicable) as provided in Section 3.2(d)(i). 

        (f)    Suzlon's
obligations as to the Delivery Schedule shall be as follows: 

        (i)    Suzlon
shall, subject to Force Majeure, Deliver each WTG in accordance with the Delivery Schedule (but in no event later than the applicable Delivery Deadline). 

16

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

If
Suzlon (subject to Force Majeure) fails to Deliver all components of a WTG by the applicable Delivery Deadline, then as Owner's sole and exclusive remedy for any such failure (except as otherwise
provided in this Section 2.1(f)), Suzlon shall pay Owner as liquidated damages and not as a penalty the following: 

	•
	As
to each WTG for which Suzlon (subject to Force Majeure) fails to Deliver all components by the applicable Delivery Deadline, *** U.S. Dollars ($***) for each day after
the Delivery Deadline applicable to such WTG (each such date being subject to Force Majeure) until the earlier of (x) the date all components of such WTG are Delivered, and (y) the date
Definitive Agreements applicable to such WTG are executed (it being acknowledged that the terms and conditions contained in such Definitive Agreements shall thereafter govern as to Suzlon's schedule
obligations). Liquidated damages that are due and payable under this Section 2.1(f), if at all, are hereinafter referred to as "Delivery Liquidated Damages". Such Delivery Liquidated Damages
shall be paid by Suzlon to Owner within thirty (30) days of the date accrued. 

Notwithstanding
the foregoing, Suzlon's aggregate liability for Delivery Liquidated Damages with respect to each WTG shall not exceed the corresponding Delivery LD Cap. If Delivery of the components
of a WTG is delayed for a period of time such that the aggregate Delivery Liquidated Damages that have accrued with respect to such WTG are equivalent to the corresponding Delivery LD Cap, and such
delay is thereafter continuing, the same shall constitute a Suzlon Default under this Agreement, whereupon Owner may either (i) terminate this Agreement solely as to such delayed WTG pursuant
to the terms of Sections 8.1 and 8.2, and seek recovery of actual damages, if any, incurred by Owner as a result of such Suzlon Default (excluding any delay-related damages incurred by Owner as a
result of the delay in Delivery of such WTG; it being agreed that Owner's sole and exclusive delay damages for such delay shall be the Delivery Liquidated Damages, subject to the corresponding
Delivery LD Cap); or (ii) keep this Agreement in full force and effect as to such delayed WTG, but seek recovery of (x) PTC Liquidated Damages as to such WTG, if ultimately applicable,
subject to the 2008 PTC LD Cap or 2009 PTC LD Cap (as applicable), and (y) actual damages, if any, incurred by Owner as a result of such Suzlon Default (excluding any delay-related damages
incurred by Owner as a result of the delay in Delivery of the components of such WTG; it being agreed that Owner's sole and exclusive delay damages for such delay shall be (x) the Delivery
Liquidated Damages, subject to the corresponding Delivery LD Cap, and (y) the PTC Liquidated Damages as to such WTG, if ultimately applicable, subject to the 2008 PTC LD Cap or 2009 PTC LD Cap
(as applicable)). Suzlon's obligation as to the payment of the liquidated damages which have accrued under this Section 2.1(f) shall remain effective and binding upon Suzlon even if Definitive
Agreements with respect to the relevant WTGs are executed by the Parties. Finally, if Suzlon is liable for Delivery Liquidated Damages under this Agreement with respect to a WTG, and Definitive
Agreements are subsequently executed with respect to such WTG, such Definitive Agreements shall clearly state that Suzlon shall have no further monetary liability for the days of Delivery delay for
which it has already paid Delivery Liquidated Damages. 

17

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

  

        (ii)   The
Parties acknowledge and agree that, notwithstanding anything to the contrary contained in this Agreement or any Definitive Agreements, Suzlon shall not charge
Owner, and Owner shall have no liability whatsoever for, storage and/or rental costs (including any transportation costs and/or expenses in moving any such WTG components to storage facilities)
incurred by Suzlon as a result of Delivery of a WTG prior to its applicable Delivery Deadline (but excluding the IDP Fee, for which Owner shall have obligation to pay to Suzlon as described in
Section 3.2(d)(ii)). However, storage and/or rental costs incurred on or after the applicable Delivery Deadline (including, without limitation, any transportation costs and/or expenses in
moving any such WTG components to storage facilities, but excluding storage and/or rental costs related to Suzlon Storage Days) shall be at Owner's cost as provided in this Agreement and (as
applicable) the Modified Obligations or the Definitive Agreements. 

        (g)   Throughout
the duration of this Agreement, the Parties shall communicate and otherwise work with each other to develop definitive schedules for incorporation into the
various Definitive Agreements, provided, however, unless the Parties otherwise agree, such schedules must be consistent with the Delivery Schedule, as amended herein. 

        (h)   By
***, Suzlon shall provide Owner with an updated version of the Delivery Schedule, which update shall identify the specific number of 2008 WTGs Suzlon shall be
contractually bound to Deliver each calendar month during 2008. In no event may the updated Delivery Schedule materially alter the Delivery Schedule attached hereto. Once mutually agreed between the
Parties, such updated Delivery Schedule shall be incorporated into this Agreement by a written amendment. 

        (i)    By
***, Suzlon shall provide Owner with another updated version of the Delivery Schedule, which update shall identify the specific number of 2009 WTGs Suzlon shall be
contractually bound to Deliver each calendar month during 2009. In no event may the updated Delivery Schedule materially alter the Delivery Schedule attached hereto. Once mutually agreed between the
Parties, such updated Delivery Schedule shall be incorporated into this Agreement by a written amendment. 

        (j)    From
time to time after *** (with respect to the 2008 WTGs) and *** (with respect to the 2009 WTGs), Suzlon shall provide Owner, solely for information purposes,
schedules identifying the anticipated number of WTGs to be Delivered on a weekly basis. It is acknowledged and agreed by the Parties that any such weekly schedules are solely for informational
purposes and create no obligation or liability for Suzlon as to weekly Deliveries. 

        (k)   Sections
2.1(h), (i) and (j) shall apply whether or not any WTGs are then subject to Modified Obligations. 

        (l)    (i)    Suzlon
shall inform Owner of any material changes to the specifications of the WTGs during the term of this Agreement and provide Owner with a good
faith opportunity to secure any such changes for any of the 2008 WTGs and/or 2009 WTGs; provided, however, the Parties shall promptly thereafter equitably adjust (by amendment to this Agreement)
Suzlon's Deadline Dates and the Contract Price to reflect the schedule and cost impact to Suzlon resulting from any such changes actually requested by Owner. If Owner does not request any such 

18

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

changes,
Suzlon shall not implement any such changes, unless Suzlon does so at its sole cost and expense. 

        (ii)   Notwithstanding
the provisions of subsection 2.1(l)(i), if Suzlon, in the ordinary course of its business, implements any upgrades as to the WTGs (and does so without
any additional cost to its other customers that are purchasing the same type of WTG), Suzlon shall implement such upgrades for the WTGs to be purchased pursuant to this Agreement at no additional cost
to Owner; provided, however, that the foregoing terms shall not apply to any WTG component after manufacturing of the relevant WTG component has commenced. 

        (iii)  Notwithstanding
the provisions of subsection 2.1(l)(i), if Suzlon, in the ordinary course of its business, implements any corrective measures to remedy a defect or
deficiency in the same type of wind turbine as the WTGs, Suzlon shall implement such corrective measures for the WTGs to be purchased pursuant to this Agreement at no additional cost to Owner (but
only if such corrective measures seek to address a defect or deficiency that affects the WTGs to be purchased pursuant to this Agreement). Notwithstanding the foregoing, nothing in this
Section 2.1(l) shall affect any guaranty or warranty provided by Suzlon under this Agreement or any Definitive Agreements, as applicable. 

        (m)  The
Parties acknowledge and agree that it shall be within Suzlon's sole discretion to determine (i) as to Projects to be located in the continental United States,
(1) those WTG components which it intends to procure outside the continental United States and deliver to a Gulf Port, and (2) those WTG components which it intends to procure within the
continental United States and make available "ex works" the manufacturer's plant, and (ii) as to Canadian Projects, (1) those WTG components which it intends to procure outside the
continental United States and deliver to a Gulf Port, and (2) those WTG components which it intends to procure within the continental United States and make available "ex works" the
manufacturer's plant; provided, however, as to Major Components, Suzlon shall provide written notice to Owner indicating its determination as to the aforementioned sourcing no later than *** (for the
2008 WTGs) or *** (for the 2009 WTGs) (each a "Sourcing Determination"). If Owner provides Suzlon with notice of its intended or likely Project Sites in the United States prior to the date Sourcing
Determinations are made, Suzlon shall reasonably consider proximity to such Project Sites in making such Sourcing Determinations. At Owner's request, Suzlon and Owner shall discuss in good faith
potential changes to the Sourcing Determination of any WTG; provided, however, that Owner shall bear the effect of any cost or schedule impact to Suzlon, if any, due to alterations in the Sourcing
Determination requested by Owner. Notwithstanding the foregoing, if Owner fails to timely issue an NTP as provided in Section 2.3 for any reason other than a Suzlon Default, Suzlon shall be
entitled in its sole discretion to revise its Sourcing Determination as to those WTGs for which no NTP was timely issued until the date that is five (5) months prior to the Delivery Deadline
for such WTGs. 

        2.2    Mechanical
Completion, Commissioning and Final Completion.    

        (a)   The
Owner shall bear full responsibility for completing the Balance of Plant at each Project Site (including, without limitation, the assembly, installation and
achievement of 

19

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

Mechanical
Completion of all WTGs in accordance with Installation Manual provided to Owner by Suzlon). The Owner acknowledges and agrees that Suzlon's obligations to be performed under this Agreement
after the achievement of Mechanical Completion of the WTGs (including, without limitation, Suzlon's warranty and guarantee obligations) are expressly conditioned upon Owner's proper assembly,
installation and achievement Mechanical Completion of the WTGs in accordance with the Installation Manual. 

        (b)   Subject
to the terms of Section 3.1(d), Suzlon shall provide technical advisor assistance to the Owner so as to answer questions the Owner or Owner's Contractors
may have during the installation and Mechanical Completion of any WTGs. If the party providing any such technical advisor assistance identifies an irregularity or error in installation, such party
shall notify the Owner of the same; provided, however, Suzlon shall not guaranty, warrant or covenant that the installation work of Owner is performed correctly and shall not be responsible for errors
or omissions of Owner in the installation process or for the failure of Owner or its contractors to properly install any WTG. In confirmation thereof, the provision of such technical advisor
assistance shall not relieve the Owner of the responsibility to ensure that the WTGs are installed and Mechanical Completion is achieved in accordance with the Installation Manual. 

        (c)   (i)    On
or before the Mechanical Completion Notice Deadline, Owner shall, as to every WTG being purchased by Owner, notify Suzlon in writing of the date
Owner expects to achieve Mechanical Completion of the WTG(s) specified in each such notice (each such notice being an "Expected Mechanical Completion Notice"). Both the expected Mechanical Completion
date provided in an Expected Mechanical Completion Notice for a WTG, as well as the actual date of Mechanical Completion of any such WTG, shall be no later than the *** (***) day after the date of
issuance of the corresponding Expected Mechanical Completion Notice (the "Mechanical Completion Deadline"). 

        (ii)   In
addition to the Expected Mechanical Completion Notice discussed above, Owner shall notify Suzlon in writing no later than *** (***) days prior to the date (the
"Expected MC Date") Owner expects to achieve Mechanical Completion of any Second Notice WTGs (each such notice being an "Second Expected Mechanical Completion Notice"). For purposes of this Agreement,
"Second Notice WTGs" shall mean (x) any WTGs which are Mechanically Completed in ***, or (y) any WTGs for which Owner submits any Notice of Mechanical Completion during the months of
***. In the event Owner delivers a Second Expected Mechanical Completion Notice for a Second Notice WTG and the Mechanical Completion Date for such WTG occurs after the Expected MC Date, Owner shall
pay to Suzlon an amount equal to the Standby Fee. For purposes of this Agreement, the "Standby Fee" shall mean an amount equal to *** U.S. Dollars ($***) for every seven (7) day period (or
fraction thereof) (beginning on the day after the Expected MC Date for a Second Notice WTG and ending upon the earlier of (i) the Mechanical Completion of such WTG or (ii) the date which
Owner instructs Suzlon in writing that it is withdrawing its Second Expected Mechanical Completion Notice as to such WTG as described below) for which a Suzlon Commissioning crew (of three
(3) individuals) is on standby (i.e., not working on the specific Second Notice WTG(s) referenced in the Second Expected Mechanical Completion Notice) at a Project Site awaiting Mechanical
Completion of such WTGs. Notwithstanding the foregoing, if a Suzlon Commissioning crew is on standby for only one (1) or two (2) days in the 

20

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

aggregate,
the Standby Fee as to such Commissioning crew may be prorated as to such one (1) or two (2) day period (e.g., if a Second Notice WTG is Mechanically Completed on the second
(2nd) day after the Expected MC Date for such WTG, the Standby Fee for such Commissioning crew shall be *** U.S. Dollars ($***), but if such Second Notice WTG is Mechanically Completed
on the ninth (9th) day after the Expected MC Date for such WTG, the Standby Fee for such Commissioning Crew shall be *** U.S. Dollars ($***)). In the event a Commissioning crew is on
standby at a Project Site, the Parties agree to reasonably cooperate as to the future utilization of such Commissioning crew; provided, however, (x) Suzlon shall be under no obligation to
utilize such Commissioning crew to Commission any WTG other than the Second Notice WTG for which they are on standby, and (y) Owner shall have the right to withdraw the Second Expected
Mechanical Completion Notice as to any Second Notice WTG for which a Suzlon Commissioning crew is or will be on standby,1 in which case (1) Owner shall resubmit a Second Expected
Mechanical Completion Notice for such WTG pursuant to the terms of this Section 2.2(c)(ii), and (2) Suzlon shall have the right to immediately withdraw such Commissioning crew from the
Project Site (it being understood that Suzlon may choose to remain at such Project Site pursuant to a mutual agreement of the Parties pursuant to the introductory clause to this sentence). The Standby
Fee shall not apply to any WTGs other than Second Notice WTGs. If, after Owner's delivery of a Second Mechanical Completion Notice as to a Second Notice WTG, an event of Force Majeure occurs that
adversely affects Owner's ability to Mechanically Complete such Second Notice WTG by the Expected MC Date, Owner shall be entitled to an equitable adjustment in such Expected MC Date reflecting the
impact of such event of Force Majeure; provided, however, (x) Owner must request such adjustment in writing to Suzlon as promptly as possible after Owner first becomes aware of such event, and
(y) all other terms and provisions of this Section 2.2(c)(ii) shall apply to such newly adjusted Expected MC Date (e.g., for the sake of clarity, if the adjustment delays the
Expected MC Date by five (5) days, and Owner does not Mechanically Complete such Second Notice WTG until the third (3rd) day after such newly adjusted Expected MC Date, Owner
shall be liable for a week's worth of Standby Fees for each Commissioning crew on standby at the Project Site). Notwithstanding the foregoing, nothing contained in this
Section 2.2(c)(ii) shall alter the Mechanical Completion Deadline as to any WTG. 

        (d)   Mechanical
Completion shall be determined in accordance with the Mechanical Completion Process (as the same may be amended from time to time by the Parties) attached
hereto as Exhibit O. Suzlon shall work in close cooperation with Owner and Owner's Contractors, including any Installation Contractor, to avoid unnecessary repetitions (where possible) in the
Mechanical Completion Process; provided, however, Suzlon shall have no liability for the occurrence of the same. 

        (e)   Suzlon
shall promptly commence and diligently pursue Commissioning work as to each WTG to completion prior to the applicable Commissioning Deadline and, as to any WTG 

1  The Parties acknowledge and agree that if such Commissioning crew is mobilized (or has begun mobilizing) in response to such Second Expected
Mechanical Completion Notice and has incurred travel expenses in relation thereto, Owner shall reimburse Suzlon for such travel expenses.

21

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

which
is Mechanically Completed or for which Owner has submitted any Notice of Mechanical Completion during the *** (***) day period prior to the PTC Qualification Date, Suzlon shall use reasonable
efforts to expedite Commissioning of such WTG (including the commencement of such Commissioning); provided, however, Parties acknowledge and agree that, notwithstanding the foregoing and anything to
the contrary contained in this Agreement, Suzlon shall be under no obligation (i) to commence Commissioning of a WTG earlier than *** (***) days prior to such WTG's Commissioning Deadline, or
(ii) to achieve Commissioning of a WTG prior to its Commissioning Deadline. Promptly after the last WTG for a Project Site is Commissioned, Suzlon and Owner shall mutually prepare a final Punch
List. 

        (f)    If
Owner has not achieved Mechanical Completion as to a WTG in accordance with this Agreement (including, without limitation, in accordance with the Installation Manual)
by the Outside Mechanical Completion Deadline, then all obligations of Suzlon related to such WTG under the Equipment Warranty, the Availability Warranty and the Power Curve Guarantee (as such terms
are defined in the Modified Obligations or any Definitive Agreements, as applicable) shall automatically terminate and be of no further force or effect (and termination of such warranties with respect
to such WTG shall be Suzlon's sole and exclusive remedy for a failure by Owner to achieve Mechanical Completion of such WTG by the Outside Mechanical Completion Deadline). 

        (g)   In
the event the Owner delivers a Notice of Mechanical Completion to Suzlon for any WTG that is not yet connected to the permanent electricity transmission system (i.e.,
the grid) and energized, the Owner shall provide at its sole cost and expense all necessary transformers, generators and other equipment and resources necessary for Suzlon to begin Commissioning. In
such event, the Owner acknowledges and agrees that Suzlon will not be able to complete Commissioning until the Owner has connected the WTG to the permanent electricity transmission system, and the
Owner shall give Suzlon no less than ten (10) Business Days' notice of the date on which such connection will occur. The Owner shall bear all of Suzlon's costs associated with any interruption
in Suzlon's ability to continue Commissioning due to lack of connection of the WTG to the permanent electricity transmission system (including, without limitation, any reasonable personnel or other
costs associated with duplicative or repetitive services provided by Suzlon). 

        (h)   If
Suzlon fails to Commission a WTG by the applicable Commissioning Deadline for reasons other than (i) Force Majeure, or (ii) the failure of Owner to
timely connect the Project to the permanent electricity transmission system (i.e., the grid) and energize the same, Suzlon shall pay Owner, as Owner's sole and exclusive remedy for any such failure
(except as otherwise provided in this Section 2.2(h)), and as liquidated damages and not as a penalty, *** U.S. Dollars ($***) for each day after the Commissioning Deadline applicable to such
WTG (each such date being subject to Force Majeure) until the date such WTG is Commissioned. Liquidated damages that are due and payable under this Section 2.2(h), if at all, are hereinafter
referred to as "Commissioning Liquidated Damages". Such Commissioning Liquidated Damages shall be paid by Suzlon to Owner within thirty (30) days of the date accrued. Notwithstanding the
foregoing, Suzlon's aggregate liability for Commissioning Liquidated Damages with respect to each WTG shall not exceed an amount equal to the Commissioning LD Cap. If Commissioning of a WTG is delayed
for a period of time such that the aggregate Commissioning Liquidated Damages that have accrued with respect to such WTG are equivalent to the corresponding Commissioning LD 

22

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

Cap,
and such delay is thereafter continuing, the same shall constitute a Suzlon Default under this Agreement, whereupon Owner may either: (i) terminate this Agreement solely as to such delayed
WTG pursuant to the terms of Sections 8.1 and 8.2, and seek recovery of actual damages, if any, incurred by Owner as a result of such Suzlon Default (excluding any delay-related damages incurred by
Owner as a result of the delay in Commissioning of such WTG; it being agreed that Owner's sole and exclusive delay damages for such delay shall be the Commissioning Liquidated Damages, subject to the
corresponding Commissioning LD Cap); or (ii) keep this Agreement in full force and effect as to such delayed WTG, but seek recovery of (x) PTC Liquidated Damages as to such WTG, if
ultimately applicable, subject to the 2008 PTC LD Cap or 2009 PTC LD Cap (as applicable), and (y) actual damages, if any, incurred by Owner as a result of such Suzlon Default (excluding any
delay-related damages incurred by Owner as a result of the delay in Commissioning of such WTG; it being agreed that Owner's sole and exclusive delay damages for such delay shall be (x) the
Commissioning Liquidated Damages, subject to the corresponding Commissioning LD Cap, and (y) the PTC Liquidated Damages, if ultimately applicable, subject to the 2008 PTC LD Cap or 2009 PTC LD
Cap (as applicable)). Finally, if Suzlon is liable for Commissioning Liquidated Damages under this Agreement with respect to a WTG, and Definitive Agreements are subsequently executed with respect to
such WTG, such Definitive Agreements shall clearly state that Suzlon shall have no further monetary liability for the days of Commissioning delay for which it has already paid Commissioning Liquidated
Damages. 

        (i)    When
Suzlon believes it has Commissioned a WTG in accordance with the Commissioning Test and Inspection Procedures, it shall promptly notify Owner in writing. Upon
receipt of such notice, Owner shall conduct those investigations and inspections it deems necessary or appropriate to determine if Commissioning of such WTG has in fact been achieved. Within two
(2) Business Days after the receipt of Suzlon's notice by Owner, the Owner shall either (i) notify Suzlon that Commissioning of the WTG has been achieved, or (ii) notify Suzlon
that Commissioning of the WTG has not been achieved and stating the reasons therefor. Should Owner fail to respond to Suzlon's notice within such two (2) Business Day period, the corresponding
WTG shall be deemed Commissioned. In the event Owner provides timely written notice that Commissioning of the WTG has not been achieved, Suzlon shall, at its sole cost and expense, immediately correct
and/or remedy the defects, deficiencies and other conditions which so prevent Commissioning of the WTG. Upon completion of such corrective and/or remedial actions, Suzlon shall resubmit its notice
stating that it believes Commissioning of the WTG has been achieved and the foregoing procedures shall be repeated until Commissioning of the WTG has in fact been achieved. Once a WTG is deemed
Commissioned, Suzlon and Owner shall thereafter execute a "Certificate of Commissioning" (in the form attached hereto as Exhibit Q) establishing and identifying the Commissioning date of that
particular WTG, which date shall be the date Suzlon sent the last notice to Owner indicating achievement of Commissioning. 

        (j)    (i)    The
Parties acknowledge and agree that in the event: 

	(x)
	Suzlon
fails to Deliver a WTG by the date which is *** (***) days prior to the PTC Qualification Date for reasons other than (i) Force Majeure, or (ii) a request by
Owner to Deliver such WTG's components which are manufactured outside the continental United States to an Alternate Port; or

23

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

	(y)
	Suzlon
fails to Commission a WTG by the PTC Qualification Date, for reasons other than (i) Force Majeure, (ii) failure of the Owner to submit an Expected Mechanical
Completion Notice for such WTG by the Mechanical Completion Notice Deadline, (iii) failure of Owner to properly install and achieve Mechanical Completion of such WTG in accordance with the
Installation Manual by the corresponding Mechanical Completion Deadline, (iv) failure of Owner to timely connect the corresponding Project to the permanent electricity transmission system
(i.e., the grid) and energize the same, (v) a request by Owner to Deliver such WTG's components which are manufactured outside the continental United States to an Alternate Port, or
(vi) the Commissioning Deadline as to such WTG occurring on (or being extended pursuant to the terms and conditions of this Agreement to) a date later than the PTC Qualification Date; and 

as
a result thereof, the WTG fails to qualify for PTCs in the amount and for the term as anticipated, Suzlon agrees to pay Owner as liquidated damages (and as Owner's sole and exclusive remedy) for
such failure, and not as a penalty, an amount equal to the PTC LD Amount for such WTG. 

        (ii)   Liquidated
damages that are due and payable under this subsection (j), if at all, are hereinafter referred to as "PTC Liquidated Damages". Such PTC Liquidated Damages
shall be paid by Suzlon to Owner within thirty (30) days of the date accrued. If the PTC Qualification Date is extended so as to allow Owner to qualify for the PTCs, or Owner otherwise
qualifies for PTCs, Suzlon shall not be liable for PTC Liquidated Damages. If WTGs later qualify for PTCs for which Suzlon has previously paid PTC Liquidated Damages (whether as a result of a change
in the PTC Qualification Date or otherwise), Owner shall reimburse Suzlon for any previously paid PTC Liquidated Damages in full (if the Owner qualifies for PTCs in at least the amount and term as in
effect on the date hereof) or in part (it being understood and agreed that if the Owner qualifies for PTCs in a lesser amount or shorter term, Owner's reimbursement to Suzlon shall be prorated to
reflect the actual PTCs for which Owner then qualifies), and shall do so within 30 days after notice from Suzlon that such payment is due. 

        (iii)  Notwithstanding
anything to the contrary contained in this Section 2.2(j), Suzlon shall not be liable for PTC Liquidated Damages (x) with respect to the
2009 WTGs, unless the PTC Qualification Date is extended to December 31, 2009 or any date thereafter, or (y) with respect to the 2008 Extended Delivery WTGs, unless the PTC Qualification
Date is extended to June 30, 2009 or any date thereafter. 

        (iv)  Suzlon's
obligations as to the payment of the PTC Liquidated Damages which have accrued under this Section 2.2(j) shall remain effective and binding upon Suzlon
even if Definitive Agreements with respect to the relevant WTGs are executed by the Parties. The Parties acknowledge that PTC Liquidated Damages, Commissioning Liquidated Damages and Delivery
Liquidated Damages are separate and independent remedies and shall not be offset or credited against each other, even though the same delay event may give rise to PTC Liquidated Damages, Commissioning
Liquidated Damages and Delivery Liquidated Damages. 

24

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

        (k)   Notwithstanding
anything to the contrary contained in this Agreement, upon the occurrence of any Seven Day Event, Suzlon may defer commencement of Commissioning of the
corresponding Excess WTGs until the corresponding Deferral Dates. For the purposes of this Section 2.2(k), the "Deferral Date" shall mean the next succeeding date on which, had such Excess WTGs
been Mechanically Completed on such date, no Seven Day Event would have otherwise occurred (it being understood that such Excess WTGs shall be included in all such Seven Day Event calculations for the
purposes of determining whether there is an occurrence of the same and for purposes of determining the Deferral Date). The Parties acknowledge and agree that, notwithstanding anything to the contrary
contained in this Agreement, Suzlon shall have no liability for PTC Liquidated Damages as to a WTG if, such WTG's Commissioning Deadline occurs on (or is extended to pursuant to this
Section 2.2(k) to) a date later than the PTC Qualification Date. 

        (l)    When
Suzlon believes that it has achieved Final Completion as to a Project, Suzlon shall so notify Owner in writing. Upon receipt of such notice, Owner shall conduct
those investigations and inspections as it deems necessary or appropriate to determine if Final Completion as to such Project has in fact been achieved. Within five (5) Business Days after the
receipt of Suzlon's notice by Owner, the Owner shall either (i) notify Suzlon that Final Completion as to such Project has been achieved, or (ii) notify Suzlon that Final Completion as
to such Project has not been achieved and stating the reasons therefor. Should Owner fail to respond to Suzlon's notice within such five (5) Business Day period, Final Completion as to such
Project shall be deemed to have been achieved. In the event Owner provides written notice that Final Completion as to a Project has not been achieved, Suzlon shall, at its sole cost and expense,
immediately correct and/or remedy the defects, deficiencies and other conditions which so prevent Final Completion of such Project. Upon completion of such corrective and/or remedial actions, Suzlon
shall resubmit its notice stating that it believes Final Completion as to such Project has been achieved and the foregoing procedures shall be repeated until Final Completion as to such Project has in
fact been achieved; provided, however, Owner must respond to Suzlon's notice within three (3) Business Days rather than five (5) Business Days. Once Final Completion as to a Project is
deemed to have been achieved, Suzlon and Owner shall thereafter execute a "Certificate of Final Completion" (in the form attached hereto as Exhibit L) establishing and identifying the Final
Completion Date, which date shall be the date Suzlon sent the last notice to Owner indicating achievement of Final Completion of such Project. 

        2.3    Issuance
of NTPs.    (a)    Subject to Article 4, no later than ***, Owner shall deliver to Suzlon
one or more notices to proceed (each a "NTP" or collectively the "NTPs") with respect to the 2008 WTGs (other than the 2008 Extended Delivery WTGs), specifying (i) the Project Site to which
each WTG shall be delivered (subject to Owner's right to redirect delivery as provided in Section 2.3(f)), (ii) the number of WTGs assigned to each Project Site, (iii) the desired
delivery dates for such WTGs (which may not in any event be contrary to or inconsistent with the Delivery Schedule), (iv) if applicable, the Alternate Port to which Owner seeks to have the WTG
components which are manufactured outside the continental United States Delivered, (v) the options, if any, Owner selects regarding whether Suzlon's scope of services will include delivery of
the WTGs from the Initial Delivery Point to the Project Site and/or installation and achievement of Mechanical Completion of the WTGs, (vi) whether the Project is expected to have a power
purchase agreement or be a "merchant plant", and (vii) what Optional SCADA Owner is electing as to such Project Site (if any). As to any 2008 WTGs (other than any 2008 

25

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

Extended
Delivery WTGs) for which Suzlon does not receive an NTP by ***, to the extent so provided in Section 4.1, the Parties' rights, duties and obligations as to the design, manufacturing,
delivery, sale, Commissioning and purchase of such WTGs shall thereupon automatically and immediately be amended to reflect the Modified Obligations (that is, from and after such date, the Parties
rights, duties and obligations as to such WTGs shall be only those provided by and pursuant to the Modified Obligations until such time as Definitive Agreements are executed in relation to the same). 

        (b)   Subject
to Article 4, no later than ***, Owner shall deliver to Suzlon one or more NTPs with respect to the 2008 Extended Delivery WTGs, specifying (i) the
Project Site to which each WTG shall be delivered (subject to Owner's right to redirect delivery as provided in Section 2.3(f)), (ii) the number of WTGs assigned to each Project Site,
(iii) the desired delivery dates for such WTGs (which may not in any event be contrary to or inconsistent with the Delivery Schedule), (iv) if applicable, the Alternate Port to which
Owner seeks to have the WTG components which are manufactured outside the continental United States Delivered, (v) the options, if any, Owner selects regarding whether Suzlon's scope of
services will include delivery of the WTGs from the Initial Delivery Point to the Project Site and/or installation and achievement of Mechanical Completion of the WTGs, (vi) whether the Project
is expected to have a power purchase agreement or be a "merchant plant", and (vii) what Optional SCADA Owner is electing as to such Project Site (if any). As to any 2008 Extended Delivery WTGs
for which Suzlon does not receive an NTP by ***, to the extent so provided in Section 4.1, the Parties' rights, duties and obligations as to the design, manufacturing, delivery, sale,
Commissioning and purchase of such WTGs shall thereupon automatically and immediately be amended to reflect the Modified Obligations (that is, from and after such date, the Parties rights, duties and
obligations as to such WTGs shall be only those provided by and pursuant to the Modified Obligations until such time as Definitive Agreements are executed in relation to the same). 

        (c)   Subject
to Article 4, no later than ***, Owner shall deliver to Suzlon one or more NTPs with respect to the 2009 WTGs, specifying (i) the Project Site to
which each WTG shall be delivered (subject to Owner's right to redirect delivery as provided in Section 2.3(f)), (ii) the number of WTGs assigned to each Project Site, (iii) the
desired delivery dates for such WTGs (which may not in any event be contrary to or inconsistent with the Delivery Schedule), (iv) if applicable, the Alternate Port to which Owner seeks to have
the WTG components which are manufactured outside the continental United States Delivered, (v) the options, if any, Owner selects regarding whether Suzlon's scope of services will include
delivery of the WTGs from the Initial Delivery Point to the Project Site and/or installation and achievement of Mechanical Completion of the WTGs, (vi) whether the Project is expected to have a
power purchase agreement or be a "merchant plant", and (vii) what Optional SCADA Owner is electing as to such Project Site (if any). As to any 2009 WTGs for which Suzlon does not receive an NTP
by ***, to the extent so provided in Section 4.1, the Parties' rights, duties and obligations as to the design, manufacturing, delivery, sale, Commissioning and purchase of such WTGs shall
thereupon automatically and immediately be amended to reflect the Modified Obligations (that is, from and after such date, the Parties rights, duties and obligations as to such WTGs shall be only
those provided by and pursuant to the Modified Obligations until such time as Definitive Agreements are executed in relation to the same). 

26

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

        (d)   Except
as provided in this Section 2.3(d), each Project Site must comprised of a minimum of *** (***) WTGs that are located on parcels of real property that are
contiguous through Owner's ownership, leasehold and/or easement interests. 

        (i)    If
a Project Site is comprised of less than *** (***) WTGs, Suzlon shall have the right to reasonably increase (1) the fee for the Warranty Period, and
(2) all costs and fees for operations and maintenance services (including, without limitation, the Warranty Service, Scheduled Maintenance, Maintenance Work, Force Majeure Work and other repair
work, in which case the Modified Obligations with respect to such Project and/or any Definitive Agreement executed with respect to such Project shall be amended to reflect such increased fees and
costs; provided, however, the adjustments described in this Section 2.3(d)(i) shall not apply if such Project Site is located within 100 miles of another wind project with an aggregate
nameplate capacity of twenty (20) MW or greater which, as of the date of the relevant NTP (or the last date upon which Owner was otherwise required to issue an NTP) uses Suzlon warranty and
maintenance services pursuant to an agreement with at least two (2) years remaining in such agreement's term, including any extended term which has been exercised by that date. At least thirty
(30) days prior to the date of the delivery of an NTP for a Project Site in the continental United States comprised of less than *** (***) WTGs, Owner may request in writing the amount of any
reasonable increase in the fees described in this Section 2.3(d)(i) that would apply to the WTGs at such a Project. As promptly as possible (but no later than thirty (30) days)
after such notice, Suzlon shall provide Owner the list of such reasonably increased costs and fees that would apply with respect to such Project Site. Following mutual consultation among the Parties
regarding such reasonably increased costs and fees, Owner may elect, in its sole discretion, whether or not to issue an NTP with respect to the Project Site. If Owner issues an NTP with respect to
such Project Site, the Modified Obligations and/or any Definitive Agreements executed with respect to such Project Site (as applicable) shall be amended to reflect such reasonably increased fees and
costs. 

        (ii)   If
a Project Site is comprised of less than *** (***) WTGs, the Availability Warranty as to the WTGs purchased for such Project Site shall be amended as provided in
Exhibits A or G (as applicable). Notwithstanding anything to the contrary contained herein, a separate Availability Warranty shall be provided for each TSA or TSIA (as applicable) executed pursuant to
this Agreement (e.g., if three (3) TSAs are executed which TSAs cover *** (***),*** (***), and *** (***) WTGs, respectively, a separate Availability Warranty shall be provided for each TSA,
notwithstanding the fact that, had a single TSA been executed for all such WTGs, a single Availability Warranty would have been provided for all *** (***) WTGs). 

        (iii)  The
Parties acknowledge and agree that, in the event of a Canadian Project, Owner shall bear all cost and schedule impacts to Suzlon as a result of the Project Site
being located in Canada (which impacts may include, without limitation, those described in Sections 2.3(d)(iv), 2.3(g)(ii), and 3.2(d)(iv)), and which impacts shall be addressed by an amendment to
this Agreement reflecting an equitable adjustment in Suzlon's costs and/or Deadline Dates to the extent impacted by the such location. 

27

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

  

        (iv)  At
least ninety (90) days prior to the date of the delivery of an NTP for a Canadian Project, Owner may, at any time, request in writing the amount of any
reasonably increased fees for operations and maintenance services that would apply to the WTGs at such Canadian Project (including, without limitation, the increased costs and fees for the Warranty
Period, Warranty Service, Scheduled Maintenance, Maintenance Work, Force Majeure Work and other repair work). As promptly as possible (but no later than ninety (90) days) after such notice,
Suzlon shall provide Owner the list of such reasonably increased costs and fees that would apply with respect to such Canadian Project. Following mutual consultation among the Parties regarding such
reasonably increased costs and fees, Owner may elect, in its sole discretion, whether or not to issue an NTP with respect to the Canadian Project. If Owner issues an NTP with respect to such Canadian
Project, the Modified Obligations and/or any Definitive Agreements executed with respect to such Canadian Project (as applicable) shall be amended to reflect such reasonably increased fees and costs. 

        (e)   For
purposes of this Agreement, no document issued by Owner which does not contain or otherwise address all of the matters required by the preceding subsections
(a) or (b), whichever is applicable, shall be deemed an NTP. 

        (f)    Owner
may, at any time and from time to time by written notice to Suzlon, redirect the delivery of one or more of the WTGs to a new or different Project Site. Owner
shall (i) be responsible (and shall reimburse Suzlon) for all reasonable increased out-of-pocket third party costs incurred by Suzlon as a result of such redirection
(including, without limitation, the reasonable increased out-of-pocket third party costs of actual transportation (including any re-routing), shipping vendor fees
and charges, applicable Taxes, insurance, permitting, handling, unloading/loading, storage (whether temporary or permanent), third party logistics management and all other reasonable increased
out-of-pocket third party costs and expenses), plus a *** percent (***%) markup on such costs, which markup and reasonable increased out-of-pocket third
party costs shall be in addition to the Contract Price, and (ii) shall agree to reasonable changes in the Deadline Dates and any corresponding Project schedule to accommodate such redirection. 

        (g)   (i)    If
Owner, at least thirty (30) days prior to the date of its delivery of an NTP for a Project in the continental United States, submits in
writing an Estimate Notice to Suzlon as to the WTGs to be referenced in such NTP, Suzlon shall (within thirty (30) days thereafter) provide Owner an estimate (a "Price Estimate") for the cost
for Delivery of such WTGs to the Alternate Port in lieu of a Gulf Port (if applicable), for delivery of the WTGs from the Initial Delivery Point to the Project Site and/or for the installation and
achievement of Mechanical Completion of such WTGs. A Price Estimate shall (i) with respect to delivery services, reflect Suzlon's estimate of actual out-of-pocket third
party costs for performing the same (including the actual estimates from Suzlon's vendors, subcontractors, suppliers, and estimates of all transportation vendor fees and charges, applicable Taxes,
insurance, permitting, handling costs, unloading/loading costs, storage costs (whether temporary or permanent), third party logistics management costs and other out-of-pocket
third party costs and expenses), plus a *** percent (***%) markup on such estimated costs, and (ii) with respect to services related to installation and achievement of Mechanical Completion,
reflect Suzlon's estimate of actual costs for performing the same (including the actual estimates from Suzlon's vendors, subcontractors 

28

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

and
suppliers, and estimates of all applicable Taxes, insurance, permitting and other out-of-pocket third party costs and expenses), plus a *** percent (***%) markup on such
estimated costs (other than such estimated insurance costs, which costs shall have a *** percent (***%) markup). Notwithstanding the foregoing, the Parties acknowledge and agree that, if Owner elects
any services described in this Section 2.3(g)(i), such Price Estimate is being provided by Suzlon to Owner solely as an estimate, and Owner shall nevertheless pay all actual and reasonable
costs for the Delivery to an Alternate Port (if applicable), for the delivery of such WTGs to the Project Site and/or for the services related to installation and achievement of Mechanical Completion
of such WTGs, all as provided in Sections 3.2(d) and 3.3, respectively, of this Agreement. 

        (ii)   If
Owner, at least ninety (90) days prior to the date of its delivery of an NTP for a Canadian Project, submits in writing an Estimate Notice to Suzlon as to the
WTGs to be referenced in such NTP, Suzlon shall as promptly as possible (but no later than ninety (90) days thereafter) provide Owner a Price Estimate for such Canadian Project as described
below. A Price Estimate for a Canadian Project shall (i) with respect to Delivery of such WTGs to an Alternate Port in lieu of a Gulf Port (if applicable) and/or delivery of such WTGs from the
Initial Delivery Point to the Project Site, reflect Suzlon's estimate of actual out-of-pocket third party costs for performing the same (including the actual estimates from
Suzlon's vendors, subcontractors, suppliers, and estimates of all transportation vendor fees and charges, applicable Taxes, insurance, permitting, handling costs, unloading/loading costs, storage
costs (whether temporary or permanent), third party logistics management costs and other out-of-pocket third party costs and expenses), plus a *** percent (***%) markup on such
estimated costs, and (ii) with respect to services related to installation and achievement of Mechanical Completion, reflect Suzlon's estimate of actual costs for performing the same (including
the actual estimates from Suzlon's vendors, subcontractors and suppliers, and estimates of all applicable Taxes, insurance, permitting and other out-of-pocket third party costs
and expenses), plus a *** percent (***%) markup on such estimated costs (other than such estimated insurance costs, which costs shall have a *** percent (***%) markup). Notwithstanding the foregoing,
the Parties acknowledge and agree that, if Owner elects any services described in this Section 2.3(g)(ii), such Price Estimate is being provided by Suzlon to Owner solely as an estimate, and
Owner shall nevertheless pay all actual and reasonable costs for the Delivery to an Alternate Port (if applicable), for the delivery of such WTGs to the Project Site, and/or for the services related
to installation and achievement of Mechanical Completion of such WTGs, all as provided in Sections 3.2(d) and 3.3, respectively, of this Agreement. 

        (h)   Suzlon
further agrees to cooperate (at no cost to Suzlon) with Owner and all of Owner's Contractors in a manner reasonably anticipated to further the development of each
Project Site. 

        (i)    At
any time Owner may submit in writing a notice to Suzlon requesting the number of foundation templates desired for the Project specified in such notice and the
requested date of delivery of such foundation templates to such Project Site. The Parties acknowledge and agree that, as to a Project Site, Owner shall be entitled to "X" foundation templates, with
"X" being the number equal to (a) the total number of WTGs at such Project Site, divided by (b) fifteen (15) (or the next whole number greater than the product of the foregoing
equation if such product renders a fraction of a whole number) (e.g., Owner shall be entitled to two (2) foundation templates for a twenty (20) WTG Project). Suzlon's provision of
foundation templates 

29

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

pursuant
to this Section 2.3(i) is included in the Contract Price; provided, however, that Owner shall reimburse Suzlon for (a) the reasonable costs of shipping or transporting
such foundation templates to the Project Site, and, (b) once Owner has completed its use of such foundation templates, the reasonable costs of shipping or transporting the same from the Project
Site to (x) another Project Site designated by Owner in writing pursuant to this Section 2.3(i), or (y) Suzlon's storage facility in the continental United States for such
foundation templates (as applicable). 

        2.4    Execution
of Definitive Agreements.    (a)    Subject to Article 4, within twenty (20) days
of Suzlon's receipt of an NTP, Suzlon and an Affiliate of Owner shall prepare, execute and deliver a set of Definitive Agreements for the associated WTGs, as more fully described in
Section 2.4(b) below. Except as otherwise expressly provided herein, upon execution of such Definitive Agreements, the terms of this Agreement, as they relate to the WTGs that are addressed in
such Definitive Agreements, shall thereupon automatically be deemed terminated, of no further force or effect, and superseded by the terms of the Definitive Agreements. In confirmation and furtherance
thereof, the Parties acknowledge and agree that (except as otherwise expressly provided herein) this Agreement shall have no bearing, application or binding effect, whether legal or otherwise, upon
any WTGs that are addressed in any executed Definitive Agreements (or with respect to any rights, remedies or obligations of the Parties with respect to such WTGs). As to any WTG for which Definitive
Agreements have not been prepared and executed within the foregoing twenty (20) day period (regardless of the reasons therefor), to the extent provided in Section 4.1, the Parties'
rights, duties and obligations as to the design, manufacturing, delivery, sale, Commissioning and purchase of such WTGs shall thereupon automatically and immediately be amended to reflect the Modified
Obligations (that is, from and after such date, the Parties rights, duties and obligations as to such WTGs shall be only those provided by and pursuant to the Modified Obligations until such time as
Definitive Agreements are executed in relation to the same). 

        (b)   The
Definitive Agreements shall be in the forms attached to this Agreement as Exhibit A, as modified to reflect the Project Site, the number of relevant WTGs,
designation of an Alternate Port (if applicable), and any other applicable terms of this Agreement. If the NTP specifies that Suzlon will install and Mechanically Complete the WTGs, the parties shall
use the TSIA form and the WMSA form. If the NTP specifies that someone other than Suzlon will perform the installation services, the parties shall use the TSA form and the WMSA form; provided,
however, the parties shall use the TSA form attached hereto as Exhibit A-1 in the event Suzlon delivers the WTGs from the Initial Delivery Point to the Project Site and the TSA form
attached hereto as Exhibit A-4 in the event Suzlon only delivers the WTGs to the Initial Delivery Point. In furtherance thereof, upon issuance of an NTP, Suzlon agrees to execute
and deliver (and Owner agrees to cause one of its Affiliates to execute and deliver) with respect to the applicable WTGs Definitive Agreements which are in the forms attached hereto as
Exhibit A and which, in all material respects, reflect the applicable terms of this Agreement; it being further agreed by the Parties that the execution and delivery of any such Definitive
Agreements shall not be unreasonably withheld. 

        2.5    Certain
Performance-Related Issues.    (a)    Notwithstanding anything to the contrary contained in this
Agreement or in any exhibit to this Agreement, the Parties acknowledge and agree that Owner has the right to withhold and/or retain the Performance 

30

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

Holdbacks
from certain Milestone Payments due under this Agreement until such time as the conditions described in this Section 2.5 are satisfied. In the event that the total amount needed for
any Performance Holdback from any designated Milestone Payment exceeds the applicable Available Milestone Amount, then the portion of any such Performance Holdback not funded from such Milestone
Payment shall be "held back" from the next succeeding Milestone Payment. For purposes of this Agreement, any amounts so withheld from a Milestone Payment shall be deemed to not have been due on such
date, and such amounts shall only be due when and if Owner is required to pay such amounts pursuant to the terms of this Section 2.5. Owner and Suzlon further agree that any such "holdback"
shall not count against the Liability Cap. 

        (b)   Suzlon
shall provide to Owner either the results of (i) a Successful V3 Test as to a wind turbine located in Australia on or prior to ***, or (ii) a
Successful V3 Test as to a wind turbine located in the United States on or prior to ***, and if Suzlon does not provide at least one such Successful V3 Test by the corresponding deadline, Owner shall
be entitled to "holdback" from the Third 2009 Milestone Payment an amount equal to *** percent (*** %) of the Contract Price (the "V3 Holdback"). For the purposes of this Agreement, a "Successful V3
Test" shall mean a power curve test of a wind turbine using the "V3" blade and achieving a *** percent (***%) or better power curve. Owner shall pay the V3 Holdback to Suzlon (and shall not be
entitled to any future V3 Holdback) upon the occurrence of the earlier of (x) ten (10) Business Days after the date Suzlon provides results, reasonably acceptable to Owner, of a
Successful V3 Test, or (y) the date the Parties enter into an amendment to this Agreement setting forth a corrective plan for Suzlon's failure to provide a Successful V3 Test, which amendment
shall be drafted in a manner substantially similar to that certain First Amendment to the Purchase & Reservation Agreement by and between Owner and Suzlon, dated as of July 7, 2006 (a
"V3 Amendment"). In the event that (x) Suzlon has not provided results, reasonably acceptable to Owner, of a Successful V3 Test, or (y) the Parties have not entered into a V3 Amendment
on or prior to ***, Suzlon agrees that Owner may retain the then-existing V3 Holdback as liquidated damages (and as Owner's sole and exclusive remedy, and not as a penalty) for failure to
either deliver a Successful V3 Test or enter into a V3 Amendment (the "V3 Liquidated Damages"). The V3 Liquidated Damages shall constitute Owner's sole and exclusive remedy should Suzlon fail to
either provide a Successful V3 Test or enter into a V3 Amendment on or prior to *** (as well as any failure of Suzlon to provide such Successful V3 Test or enter into a V3 Amendment at any time after
such date); it being acknowledged and agreed by the Parties that Suzlon's liability, if any, for the V3 Liquidated Damages relates solely to Suzlon's failure to provide a Successful V3 Test or enter
into a V3 Amendment on or prior to *** (as well as any failure of Suzlon to provide such Successful V3 Test or enter into a V3 Amendment at any time after such date) and to no other covenant or
obligation of Suzlon under this Agreement. Owner acknowledges and agrees that if any V3 Liquidated Damages are payable pursuant to this Agreement and any Power Curve Liquidated Damages are payable at
a Project pursuant to this Agreement or any Definitive Agreement, such Power Curve Liquidated Damages shall be offset by an amount equivalent to the V3 Liquidated Damages Share for such Project. 

        (c)   If
Suzlon fails to install a Preliminary Power Plant at the Sleeping Bear Wind Farm prior to the Effective Date, Owner shall be entitled to "holdback" from the Third
2008 Milestone Payment an amount equal to *** U.S. Dollars ($***) (the "Preliminary PP Holdback"). For the purposes of this Agreement, a "Preliminary Power Plant" means a preliminary version of a
supervisory control and data acquisition system power plant that (i) is 

31

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

capable
of meeting the active power regulation specifications of the SC-Power Plant (as indicated on Exhibit N hereto), and (ii) has been installed at the Sleeping Bear Wind
Farm and has been successfully tested by Owner to curtail and regulate the active power from such wind farm and start and stop such wind farm in accordance with the Preliminary PP Test Procedures.
Owner acknowledges and agrees that such testing of the Preliminary Power Plant by Owner shall be concluded no later than fourteen (14) days following delivery to Owner by Suzlon of a notice
that the Preliminary Power Plant has been installed and is ready for testing. Owner shall pay the Preliminary PP Holdback to Suzlon (and shall not be entitled to any future Preliminary PP Holdback)
upon (x) Suzlon's installation of a Preliminary Power Plant at the Sleeping Bear Wind Farm that has passed the Preliminary PP Test Procedures, or (y) in the event Suzlon's installation
of a Preliminary Power Plant at the Sleeping Bear Wind Farm does not occur by ***, as a result of delay or interference by Owner or "owner" of the Sleeping Bear Wind Farm or their contractors or
subcontractors (including, without limitation, delay relating to any communications interface), the earlier of (I) the occurrence of clause (x), and (II) Suzlon's provision of a
report reasonably acceptable to Owner (Owner's acceptance not to be unreasonably withheld) demonstrating that Suzlon's preliminary version of a supervisory control and data acquisition system power
plant is capable of meeting the active power regulation specifications of the SC-Power Plant (as indicated on Exhibit N hereto) and has the ability to curtail and regulate power of
a wind farm and start and stop such wind farm (even though such power plant has not been installed and tested at the Sleeping Bear Wind Farm). 

        (d)   If
Suzlon fails to install an Applicable SC-Power Plant at one (1) Applicable Wind Farm on or prior to the Applicable Date, regardless of whether such
failure was the result of Force Majeure or any other reason, (i) Owner shall be entitled to "holdback" from the next Milestone Payment occurring after the Applicable Date (the "Next Milestone
Payment") an amount equal to *** U.S. Dollars ($***) (the "Full PP Holdback") and (ii) Suzlon shall promptly retain, at Suzlon's sole expense, a nationally recognized, independent expert
(mutually agreeable to the Parties) in supervisory control and data acquisition systems and the development thereof, which expert shall, at Suzlon's sole direction and sole expense, either promptly
(x) modify or enhance the existing power plant program and devices to achieve the SC-Power Plant specifications (as described on Exhibit N hereto) at such one
(1) Applicable Wind Farm, or (y) provide a third-party supervisory data control and acquisition system that provides the equivalent functionality of the SC-Power Plant,
install the same at one (1) Applicable Wind Farm, and test the same in accordance with the Full PP Test Procedures (the provision of (x) or (y) being an "Alternate Power Plant").
Suzlon agrees to provide such expert with access to its SC-Power Plant and software codes sufficient to enable such expert to perform the tasks set forth in the preceding sentence. For the
purposes of this Agreement, an "Applicable SC-Power Plant" shall mean an SC-Power Plant that has been installed at one (1) Applicable Wind Farm and successfully tested
in accordance with the Full PP Test Procedures. Owner acknowledges and agrees that testing of the Applicable SC-Power Plant or Alternate Power Plant (as applicable) by Owner shall be
concluded no later than fourteen (14) days following delivery to Owner by Suzlon or the expert (as applicable) of a notice that the Applicable SC-Power Plant or Alternate Power
Plant has been installed and is ready for testing. In the event Suzlon has not yet provided to Owner an Applicable SC-Power Plant or an Alternate Power Plant at one (1) Applicable
Wind Farm by the later of (x) the date the Fourth 2009 Milestone Payment is due and (y) the date the Next Milestone Payment is due (such later date being the "Threshold Date"), Owner
shall additionally be entitled to "holdback" from each Milestone Payment occurring after the 

32

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

Threshold
Date an amount equal to *** percent (***%) of each such Milestone Payment (which such amount shall be added to any existing Full PP Holdback). Upon Suzlon's installation of an Applicable
SC-Power Plant or Alternate Power Plant at one (1) Applicable Wind Farm, Owner shall pay the Full PP Holdback to Suzlon (and shall not be entitled to any future Full PP Holdback). 

        (e)   The
Parties further acknowledge and agree that Owner has the right pursuant to the Performance Side Letter to withhold amounts from certain Milestone Payments due under
this Agreement until such time as the conditions described in the Performance Side Letter are satisfied. Any amounts so withheld from a Milestone Payment shall be deemed to not have been due on such
date, and such amounts shall only be due when and if Owner is required to make such amounts pursuant to the terms of the Performance Side Letter. Owner and Suzlon further agree that any such Side
Letter Holdback shall not count against the Liability Cap. The terms and conditions of the Performance Side Letter are expressly incorporated herein and made a part of this Agreement. 

        (f)    Notwithstanding
the foregoing and anything to the contrary contained in this Agreement, Suzlon's failure to perform any obligation set forth in this Section 2.5
or the Performance Side Letter shall not be deemed a Suzlon Default or a default under this Agreement; it being understood and agreed by the Parties that Owner's sole and exclusive recourse for
Suzlon's failure to perform any obligation pursuant to this Section 2.5 or the Performance Side Letter shall be to withhold the applicable Performance Holdback and/or Side Letter Holdback until
the corresponding obligation is satisfied pursuant to Section 2.5 or the Performance Side Letter, as applicable (or, if applicable, to retain as liquidated damages the V3 Liquidated Damages
pursuant to Section 2.5(b)). 

        (g)   If,
by reason of the execution of one (1) or more Definitive Agreements, the amount of the Milestone Payments provided under this Agreement are no longer adequate
to permit Owner to withhold a Performance Holdback or a Side Letter Holdback, Suzlon shall permit Owner to "hold back" the applicable Performance Holdback(s) and/or Side Letter Holdback(s) from the
"milestone payments" next due under any set of Definitive Agreements selected by Owner. Suzlon, Owner and the "owner" under such Definitive Agreements shall enter into a side letter agreement
documenting the same. 

        2.6    Type
Certificate.    (a)    The WTGs to be supplied by Suzlon to the Owner under this Agreement shall be
materially consistent with the wind turbine generators for which the Germanischer Lloyd Type Certificate was issued, and will include any modifications or upgrades that were implemented in order to
obtain the Germanischer Lloyd Type Certificate. 

        (b)   In
the event a Final Payment becomes payable pursuant to this Agreement and Suzlon has not delivered the Germanischer Lloyd Type Certificate to Owner, the Parties
acknowledge and agree that the following shall occur: 

        (i)    For
Final Payments relating to 2008 WTGs, Owner shall be entitled to "holdback" from such Final Payments an amount equal to *** percent (***%) of the 2008 Contract Price
for each such 2008 WTG (collectively, the "2008 GL Holdback"). In the event Suzlon fails to deliver the Germanischer Lloyd Type Certificate to Owner on 

33

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

or
prior to ***, Suzlon agrees that Owner may retain the then-existing 2008 GL Holdback, as well as all future 2008 GL Holdback, as liquidated damages (and as Owner's sole and exclusive
remedy, and not as a penalty) for failure to deliver the Germanischer Lloyd Type Certificate on or prior to *** (the "2008 GL Liquidated Damages"). Notwithstanding the foregoing, in the event Suzlon
delivers the Germanischer Lloyd Type Certificate to Owner on or prior to ***, Owner shall pay to Suzlon any then-existing 2008 GL Holdback and shall not be entitled to any future 2008 GL
Holdback with respect to 2008 WTGs. The 2008 GL Liquidated Damages shall constitute Owner's sole and exclusive remedy should Suzlon fail to deliver the Germanischer Lloyd Type Certificate to Owner on
or prior to *** (as well as any failure of Suzlon to deliver such certificate at any time after such date); it being acknowledged and agreed by the Parties that Suzlon's liability, if any, for 2008 GL
Liquidated Damages relates solely to Suzlon's failure to deliver the Germanischer Lloyd Type Certificate to Owner on or prior to *** (as well as any failure of Suzlon to deliver such certificate at
any time after such date) and to no other covenant or obligation of Suzlon under this Agreement. 

        (ii)   For
Final Payments relating to 2009 WTGs, Owner shall be entitled to "holdback" from such Final Payments an amount equal to *** percent (***%) of the 2009 Contract
Price for each such 2009 WTG (collectively, the "2009 GL Holdback"). In the event Suzlon fails to deliver the Germanischer Lloyd Type Certificate to Owner on or prior to ***, Suzlon agrees that Owner
may retain the then-existing 2009 GL Holdback, as well as all future 2009 GL Holdback, as liquidated damages (and as Owner's sole and exclusive remedy, and not as a penalty) for failure to
deliver the Germanischer Lloyd Type Certificate to Owner on or prior to *** (the "2009 GL Liquidated Damages", collectively with the 2008 GL Liquidated Damages, the "GL Liquidated Damages").
Notwithstanding the foregoing, in the event Suzlon delivers the Germanischer Lloyd Type Certificate to Owner on or prior to ***, Owner shall pay to Suzlon any then-existing 2009 GL
Holdback and shall not be entitled to any future 2009 GL Holdback with respect to 2009 WTGs. The 2009 GL Liquidated Damages shall constitute Owner's sole and exclusive remedy should Suzlon fail to
deliver the Germanischer Lloyd Type Certificate to Owner on or prior to *** (as well as any failure of Suzlon to deliver such certificate at any time after such date); it being acknowledged and agreed
by the Parties that Suzlon's liability, if any, for 2009 GL Liquidated Damages relates solely to Suzlon's failure to deliver the Germanischer Lloyd Type Certificate to Owner on or prior to *** (as
well as any failure of Suzlon to deliver such certificate at any time after such date) and to no other covenant or obligation of Suzlon under this Agreement. 

 
 

ARTICLE 3    
    
    CONTRACT PRICE; PAYMENTS TO SUZLON    
    

        3.1    Contract
Price.    (a)    As consideration for the sale of each 2008 WTG by Suzlon, Owner agrees to pay
Suzlon the price of *** U.S. Dollars (US $***) for each such WTG (the "2008 Contract Price"). 

34

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

   
        (b)   As consideration for the sale of each 2009 WTG by Suzlon, Owner agrees to pay Suzlon the price of *** U.S. Dollars (US $***) for each such WTG (the "2009 Contract
Price"). 

        (c)   For
purposes of this Agreement, the "Contract Price" shall be the sum of (i) the 2008 Contract Price multiplied by the total number of 2008 WTGs (the "Total 2008
Contract Price"), and (ii) the 2009 Contract Price multiplied by the total number of 2009 WTGs (the "Total 2009 Contract Price"). The Contract Price is not subject to adjustment for exchange
rate fluctuations. 

        (d)   Each
2008 Contract Price for a 2008 WTG and each 2009 Contract Price for a 2009 WTG in this Section 3.1 includes (i) all costs to design and manufacture
the WTG or any component thereof (including acquisition of materials for the WTG), (ii) as to those WTG components manufactured outside the continental United States, all costs to ship such WTG
components to a Gulf Port, to clear United States customs, and to initially unload the same at the dockside of such port from the ship and, as to those WTG components manufactured within the
continental United States, all costs to make such WTG components available for shipment "ex works" a manufacturer's plant in the United States, (iii) except as provided below, technical advisor
assistance during Mechanical Completion (if the WTGs are to be Mechanically Completed by Owner), (iv) Commissioning of each WTG, and (v) the Included SCADA. 

For
purposes of this Agreement, "technical advisor assistance" shall mean the provision of a technical advisor(s) to answer questions posed by Owner during Owner's installation of a WTG; which
advisor(s) (a) shall be qualified to perform the tasks for which they are assigned pursuant to this Section 3.1(d), and (b) shall provide, without additional charge and at Owner's
direction pursuant to this Section 3.1(d), an aggregate number of man-hours of assistance to Owner equal to (i) twelve (12), multiplied by (ii) the number of WTGs
actually purchased by Owner under this Agreement (collectively, the "Aggregate TA Hours"); provided, however, that Suzlon shall provide additional technical advisor assistance to Owner, at no cost to
Owner, if such assistance is necessary to cure any defects or deficiencies in the WTGs
or related software. The parties further agree that, once the Aggregate TA Hours have been exhausted through Suzlon's performance of the same pursuant to TA Requests, any additional assistance
provided by a technical advisor pursuant to TA Requests shall be at Owner's cost, at a rate of *** U.S. Dollars ($***) per day, for each technical advisor (the "Additional TA Fees"). Notwithstanding
anything to the contrary contained in this Agreement or any set of Definitive Agreements, Owner may allocate the Aggregate TA Hours among the WTGs actually purchased under this Agreement (including
those WTGs then covered by Modified Obligations or Definitive Agreements) in such amounts as the Owner may desire (e.g., ten (10) technical advisor assistance hours for one WTG, thirty
(30) technical advisor assistance hours for another WTG, and so on); provided that Owner shall compensate Suzlon for all Additional TA Fees earned once the Aggregate TA Hours have been
exhausted (and regardless of whether the Aggregate TA Hours are exhausted in connection with WTGs subject to Modified Obligations and/or Definitive Agreements). In confirmation and furtherance
thereof, and notwithstanding anything in this Agreement to the contrary, Owner agrees (i) to pay Suzlon any Additional TA Fees earned by Suzlon as provided above, and (ii) that such
payment obligation shall remain binding upon Owner even as to WTGs which are subject to Definitive Agreements. Owner and Suzlon covenant and agree that, as to each Project, they shall work together to
forecast when technical advisor assistance shall be needed for such Project, all in accordance with such Project's WTG 

35

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

delivery
schedule. Owner covenants and agrees that, as to each Project, Owner shall provide Suzlon with twenty-one (21) days advance written notice of Owner's desire for technical
advisor assistance in relation to such Project (along with the estimated aggregate number of desired man-days of technical advisor assistance and the proposed schedule of such assistance)
(each, a "TA Request"). To the extent Owner thereafter wishes to amend a TA Request, it shall provide Suzlon with five (5) days advance written notice. Suzlon is under no obligation to
implement technical advisor assistance pursuant to a TA Request or modification thereof until the twenty-one (21) day or five (5) day notice period, as applicable, has lapsed
(unless said modification reduces the aggregate number of desired man-days), but shall use commercially reasonable efforts to implement such request as soon as reasonably possible. The
Owner under this Agreement shall have the right to determine which technical advisor assistance hours are included in the Aggregate TA Hours and shall have the right to determine which, if any, of the
Aggregate TA Hours shall be allocated to any "Projects" under any Definitive Agreements. Notwithstanding anything to the contrary contained herein, including the provision of TA Requests by Owner
under this Agreement, Suzlon shall receive no credit for, and shall not be entitled to charge Owner for, any technical advisor assistance hours for which a technical advisor is available to a Project,
but unable to provide technical advisor assistance due to delays in the Mechanical Completion activities attributable to Suzlon or its contractors or suppliers. Commencing on the date hereof, Suzlon
shall provide to Owner monthly reports summarizing the technical advisor assistance hours provided pursuant to TA Requests by Suzlon to Owner under this Agreement or any "owner" under any Definitive
Agreement. The provisions of this paragraph shall continue to apply with respect to WTGs covered by Definitive Agreements, notwithstanding Section 2.4(a) of the Agreement 

        3.2    Milestone
Payments.    (a)    Upon completion of the following "Milestones" with respect to the 2008 WTGs
and the 2009 WTGs, the corresponding portion of the Contract Price shall be due and payable to Suzlon (each, a "Milestone Payment"): 

	Milestone	 	WTGs to Which

Payment Applies	 	Milestone Payment
	

Reservation Payment	
 	

All WTGs	
 	

*** U.S. Dollars ($***) (the "Reservation Payment")
	

Execution of this Agreement	
 	

All WTGs	
 	

*** U.S. Dollars ($***), representing *** percent (*** %) of the Total 2008 Contract Price and *** percent (*** %) of the Total 2009 Contract Price, less the Reservation Payment.
	

Execution of this Agreement	
 	

2008 WTGs	
 	

*** U.S. Dollars ($***), representing *** percent (*** %) of the Total 2008

36

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

	Milestone	 	WTGs to Which

Payment Applies	 	Milestone Payment
	

 	
 	

 	
 	

Contract Price, plus the LVRT Fee for all 2008 WTGs (the "Third 2008 Milestone Payment")
	

***	
 	

2009 WTGs	
 	

*** U.S. Dollars ($***), representing *** percent (*** %) of the Total 2009 Contract Price (the "Third 2009 Milestone Payment")
	

***	
 	

2009 WTGs	
 	

*** U.S. Dollars ($***), representing *** percent (*** %) of the Total 2009 Contract Price, plus the LVRT Fee for all 2009 WTGs and (if applicable) the Climb-Assist Fee for all 2009 WTGs (provided,
however, that any Climb-Assist Election issued before this date with respect to the 2009 WTGs must be accompanied by the Climb-Assist Fee for all 2009 WTGs) (the "Fourth 2009 Milestone Payment")
	

Date that bills of lading have been issued for all Major Components of a WTG (however, as to the Major Components which are manufactured within the continental United States, it shall be the date an "ex works certificate" is issued and not a bill of
lading)	
 	

All WTGs	
 	

*** (*** %) of the applicable Contract Price for each WTG (i.e., pro rate the payment for each WTG) (the "Bill of Lading/Ex Works Milestone Payment")
	

Earlier of (i) delivery of all Major Components of a WTG to a Project	
 	

All WTGs	
 	

*** (*** %) of the applicable Contract Price

37

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

	Milestone	 	WTGs to Which

Payment Applies	 	Milestone Payment
	

Site, or (ii) fourteen (14) days after Delivery of such Major Components2	
 	

 	
 	

for each WTG (i.e., pro rate the payment for each WTG)
	

Completion of Commissioning of each WTG (provided if Mechanical Completion of the WTGs is not part of Suzlon's scope of work, such payment will be the earlier of (i) completion of Commissioning of such WTG, (ii) thirty (30) days after delivery of all
Major Components of such WTG to a Project Site (plus any Suzlon Storage Days occurring after delivery to the Project Site), or (iii) sixty (60) days after the later of (x) Delivery of all Major Components of such WTG (plus any Suzlon Storage Days)
and (y) the Delivery Deadline of such WTG	
 	

All WTGs	
 	

*** percent (***%) of the applicable Contract Price (i.e., pro rate the payment for each WTG)
	

Final Completion with respect to a Project (provided if Mechanical Completion of the WTGs is not part of Suzlon's scope of work, such payment will be the earlier of (i) Final Completion with respect to a Project, (ii) ninety (90) days after delivery
of all Major Components of all WTGs to a Project Site (plus any Suzlon Storage Days occurring after delivery of all WTGs to the Project Site), or (iii) one hundred twenty (120) days after the later of (x) Delivery of all Major Components of all WTGs
(plus any Suzlon Storage Days) and (y) the	
 	

All WTGs	
 	

*** percent (***%) of the applicable Contract Price (prorated for each Project Site, which is determined on the basis of the number of WTGs at each such Project Site) (the "Final Payment"); provided in the event of an Alternate Final Milestone, such
Milestone Payment shall be the Final Payment minus the Punch List Holdback applicable to

2 NOTE: If this Milestone occurs prior to the first day of the month immediately preceding the month in which the Delivery Deadline for such WTG occurs, then this
Milestone Payment shall be payable on the later of (x) such first day of the month immediately preceding the month in which the Delivery Deadline for such WTG occurs or (y) the date specified in
Section 3.4(c) as to the Application for Payment for such Milestone.

38

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

	Milestone	 	WTGs to Which

Payment Applies	 	Milestone Payment
	

last Delivery Deadline of any WTG (the achievement of such Milestone under either clause (ii) or clause (iii) being an "Alternate Final Milestone")	
 	

 	
 	

such Project, as further described in Section 3.4(e)).
	

Final Completion with respect to a Project	
 	

All WTGs	
 	

Punch List Holdback applicable to such Project Site

        (b)   The
Parties acknowledge and agree that Owner has previously paid the Reservation Payment of *** U.S. Dollars ($***) and that Owner shall make the remaining Milestone
Payments as to all WTGs as required by the terms of this Article 3; provided, however, (i) as to those WTGs for which Definitive Agreements have been executed, all subsequent Milestone
Payments for such WTGs shall be made pursuant to the terms of such Definitive Agreements (the executed version of which shall reflect the Milestone Payment schedule in Section 3.2(a)), and
(ii) as to those WTGs for which the Modified Obligations are effective, all subsequent Milestone Payments for such WTGs shall be made in accordance with the Modified Obligations. 

        (c)   For
purposes of this Agreement, a "bill of lading" shall mean a bill of lading for the relevant Major Component that has been provided by a shipper from outside the
continental United States and an "ex works certificate" shall mean a certificate issued by Suzlon indicating that the relevant Major Component that was manufactured within the continental United
States is available for shipment "ex works" the manufacturer's plant. 

        (d)   Owner
shall reimburse Suzlon for the following actual and reasonable costs (and associated markups, where applicable), which costs and markups shall be in addition to
the Contract Price (the "Reimbursable Expenses"): 

        (i)    In
the event Owner requests Suzlon to Deliver any WTG components which are manufactured outside the continental United States, including any WTGs subject to Modified
Obligations, to an Alternate Port, the actual and reasonable increased out-of-pocket third party costs incurred by Suzlon in Delivering the components to such Alternate Port in
lieu of a Gulf Port (including, without limitation, the reasonable increased out-of-pocket third party costs of actual transportation (including any re-routing),
shipping vendor fees and charges, applicable Taxes, insurance, permitting, handling, unloading/loading costs, storage costs (whether temporary or permanent), third party logistics management costs and
all other reasonable increased out-of-pocket third party costs and expenses), plus a *** percent (***%) markup on the lower of: (x) the Price Estimate as to such costs
and (y) the actual and reasonable out-of-pocket third party costs, which costs and markup shall be in addition to the Contract Price (or, in the event 

39

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

there
is no Price Estimate as to such costs, a *** (***%) markup on such actual and reasonable out-of-pocket third party costs); 

        (ii)   An
amount equal to *** U.S. Dollars ($***) per WTG (the "IDP Fee") for (w) transporting any WTG's components which are manufactured outside the continental
United States from the initial unloading point dockside at a Gulf Port to the first place of rest at the temporary storage location at such port (or nearby if such location is designated by the port
authority to be an area external to the port where the WTG component will be made available for inland transportation to a Project Site) (i.e., the location described in subsection (a) of the
definition of Initial Delivery Point); provided, however, Owner shall bear any additional cost impacts to Suzlon's performance of the same at an Alternate Port (which impact shall be addressed by an
amendment to this Agreement reflecting an equitable adjustment, if any, in the IDP Fee), (x) the packing of any WTG's components in a condition ready for inland transportation by truck from the
Initial Delivery Point in accordance with applicable federal, state, municipal and local law (including, without limitation, any restrictions on "divisible loads") (y) the covering, prior to
their inland transportation from the Initial Delivery Point to a Project Site, of the rotor shaft opening of such WTG's Nacelle and the open ends of such WTG's Tower sections in protective tarps to
prevent dirt from entering such openings; provided, however, the IDP Fee as to such WTG shall be adjusted downward by *** U.S. Dollars ($***) for every Tower section and/or Nacelle that requires deep
cleaning or power washing to its internal surfaces upon arrival at the Project Site as a result the failure of Suzlon to properly tarp the aforementioned openings; it being acknowledged and agreed by
the Parties that the foregoing downward adjustment shall be Owner's sole and exclusive remedy for such failure, and (z) loading of the WTG components at the Initial Delivery Point onto the
inland transportation vehicles for delivery to the Project Site or vehicles to transport the WTG components to storage, it being understood and agreed that: 

        (1)   if
WTG components are Delivered before the Delivery Deadline, and after such one-time loading, are placed into storage as a result of such early Delivery,
the cost of the subsequent loading of such components at the storage location for transportation to the Project Site shall be borne by Suzlon (unless such components remain in storage beyond the
Pick-Up Deadline (as defined in the Modified Obligations)) (or, in the event (x) Owner requests delivery of the WTG components to the Project Site, (y) WTG components are
Delivered before the Delivery Deadline and, (z) after such one-time loading, such WTG components are placed into storage as a result of such early Delivery, the cost of the
subsequent loading of such WTG components at the storage location for transportation to the Project Site shall be borne by Suzlon (unless such WTG components remain in storage at Owner's direction
beyond the date that Suzlon would otherwise have removed such WTG from storage for inland transportation to the Project Site); 

        (2)   if
WTG components are Delivered before the Delivery Deadline, and after such one-time loading, are placed into storage as a result of such early Delivery and
remain in storage beyond the Pick-Up Deadline (as defined in the 

40

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

Modified
Obligations), the cost of the subsequent loading of such components at the storage location for transportation to the Project Site shall be borne by Owner (or, in the event (x) Owner
requests delivery of the WTG components to the Project Site, (y) WTG components are Delivered before the Delivery Deadline and, (z) after such one-time loading, such WTG
components are placed into storage as a result of such early Delivery but remain in storage at Owner's direction beyond the date that Suzlon would otherwise have removed such WTG components from
storage for inland transportation to the Project Site, the cost of the subsequent loading of such WTG components at the storage location for transportation to the Project Site shall be borne by
Owner); and 

        (3)   if
WTG components are Delivered on or after the Delivery Deadline, and after such one-time loading, are placed into storage, the cost of the subsequent
loading of such components at the storage location for transportation to the Project Site shall be borne by Owner (or, in the event (x) Owner requests delivery of the WTG components to the
Project Site, (y) WTG components are Delivered on or after the Delivery Deadline, and (z) after such one-time loading are (1) placed into storage at Owner's direction,
or (2) are placed into storage by Suzlon but remain in storage at Owner's direction beyond the date that Suzlon would otherwise have removed such WTG components from storage for inland
transportation to the Project Site, the cost of the subsequent loading of such WTG components at the storage location for transportation to the Project Site shall be borne by Owner). 

Any
subsequent loading of the WTG components at the storage location as provided above shall be performed by Owner (unless Owner requests delivery of the WTG components to the Project Site, in which
case such subsequent loading shall be Suzlon's obligation), but the cost of performing such loading shall be borne by the Party responsible for such cost as provided in the preceding Clauses
(1) through (3). Notwithstanding anything to the contrary contained in this Agreement, under all circumstances Owner shall pay Suzlon the IDP Fee, and Suzlon shall perform the services
identified in this Subsection 3.2(d)(ii) for which the IDP Fee is payable, and regardless of whether the WTG components are Delivered before, on or after the Delivery Deadline; 

        (iii)  In
the event Owner requests Suzlon to deliver the WTGs to a Project Site in the continental United States, the actual and reasonable
out-of-pocket third party costs incurred by Suzlon after Delivery of the WTG components in relation to the delivery of such WTG components to the Project Site (including,
without limitation, the reasonable out-of-pocket third party costs of actual transportation from the Initial Delivery Point to a Project Site (including any
re-routing), transportation vendor fees and charges, applicable Taxes, insurance, permitting, handling costs, unloading/loading costs, storage costs (whether temporary or permanent and
whether at the Initial Delivery Point or elsewhere), third party logistics management costs and all other reasonable out-of-pocket third party costs and expenses), plus a ***
percent (***%) markup on the lower of: (x) the Price Estimate as to such costs and (y) the actual and reasonable out-of-pocket third party costs, which costs and
markup shall be in addition to the Contract Price (or, in the event 

41

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

there
is no Price Estimate as to such costs, a *** (***%) markup on such actual and reasonable out-of-pocket third party costs); 

        (iv)  In
the event Owner requests Suzlon to deliver the WTGs to the Project Site for a Canadian Project, the actual and reasonable out-of-pocket third
party costs incurred by Suzlon after Delivery of the WTG components in relation to the delivery of such WTG components to the Project Site (including, without limitation, the reasonable
out-of-pocket third party costs of actual transportation from the Initial Delivery Point to a Project Site (including any re-routing), shipping vendor fees and
charges, applicable Taxes (whether United States or Canadian, including, without limitation and for the sake of clarity, Canadian import duties and tariffs), insurance, permitting, handling costs,
unloading/loading costs, storage costs (whether temporary or permanent and whether at the Initial Delivery Point or elsewhere), third party logistics management costs and all other reasonable
out-of-pocket third party costs and expenses), plus a *** percent (***%) markup on the lower of: (x) the Price Estimate as to such costs and (y) the actual and
reasonable out-of-pocket third party costs, which costs and markup shall be in addition to the Contract Price (or, in the event there is no Price Estimate as to such costs, a
*** (***%) markup on such actual and reasonable out-of-pocket third party costs); 

        (v)   All
fees for technical advisor assistance as described in Section 3.1(d) 

        (vi)  All
reasonable installation and Mechanical Completion costs described in Section 3.3; 

        (vii) All
redirection costs (plus markup) as described in Section 2.3(f); 

        (viii) Subject
to Section 2.1(f)(ii), all storage or rental costs (including, without limitation, those described in Section 9.3 and 11.2 of Exhibit G
attached hereto); 

        (ix)  All
reasonable shipping and transportation costs for the foundation templates as described in Section 2.3(i); 

        (x)   All
Optional SCADA costs as described in Section 3.2(g); and 

        (xi)  Any
other costs and expenses that Owner shall reimburse to Suzlon pursuant to the terms and conditions of this Agreement. 

        (e)   The
Parties acknowledge and agree that Owner has selected the LVRT System for the WTGs. Owner shall include in each of the Third 2008 Milestone Payment and the Fourth
2009 Milestone Payment an amount equal to *** U.S. Dollars ($***) (representing *** U.S. Dollars ($***) per WTG; with the aggregate amount being the "LVRT Fee"), which LVRT Fee shall be in addition to
the Contract Price. The Parties acknowledge and agree that any monetary or schedule impact to Suzlon as a result of FERC making the requirements for LVRT Systems more stringent subsequent to the
Effective Date shall be borne by Owner alone (and shall be implemented by an amendment to this Agreement reflecting an equitable adjustment in Suzlon's costs and/or Deadline Dates as a result of the
same); provided, however, that Suzlon shall credit owner for any actual savings (if applicable) to Suzlon as a result of the same. 

42

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

        (f)    If
Owner elects to order the Climb-Assist System for the 2008 WTGs and/or the 2009 WTGs, Owner shall deliver written notice of such election (accompanied by the
applicable Climb-Assist Fee) to Suzlon no later than the applicable Climb-Assist Election Deadline (the "Climb-Assist Election"); it being understood and agreed by the Parties that Owner's
Climb-Assist Election must be an election for all 2008 WTGs and/or all 2009 WTGs (as applicable) and shall in no event be a partial election of the Climb-Assist System for less than the full number of
such 2008 WTGs and/or 2009 WTGs. For purposes of this Agreement, no document issued by Owner shall be deemed to be a Climb-Assist Election unless it is accompanied by the corresponding Climb-Assist
Fee. In the event Owner fails to deliver a Climb-Assist Election by the applicable Climb-Assist Election Deadline, the parties acknowledge and agree that Suzlon shall have no obligation to provide
such Climb-Assist System for those WTGs for which such deadline has passed. 

        (g)   If
Owner elects to order any of the Optional SCADA as to a Project Site, Owner shall deliver written notice of such election in the NTP for such Project Site as
described in Section 2.3. At least thirty (30) days prior to the date of the delivery of an NTP for such Project Site, Owner may, at any time, request in writing the cost of including
any of the Optional SCADA at such Project Site (other than the cost for SC-Power Plant, which the Parties hereby acknowledge and agree shall be (x) *** U.S. Dollars ($***) for
Projects consisting of one hundred (100) or fewer WTGs, and (y) *** U.S. Dollars ($***) for Projects consisting of greater than one hundred (100) WTGs). As promptly as possible
(but no later than thirty (30) days) after such notice, Suzlon shall provide Owner with a quote of such cost(s), which quote shall remain effective for fifteen (15) days. If Owner issues
an NTP electing any Optional SCADA with respect to such Project Site, the Modified Obligations and/or any Definitive Agreements executed with respect to such Project Site (as applicable) shall be
amended to reflect such quoted costs, which costs shall be in addition to the Contract Price. Notwithstanding a failure by Owner to timely request a quote as to any Optional SCADA or Suzlon's quote no
longer remaining effective pursuant to this Section 3.2(g), Owner may still obtain such Optional SCADA, but shall pay Suzlon all actual and reasonable costs incurred by Suzlon in providing such
Optional SCADA (other than the costs for SC-Power Plant, which shall be as described above), which costs shall be in addition to the Contract Price. 

        3.3    Mechanical
Completion Costs.    If Owner requests Suzlon's installation and Mechanical Completion services, in
addition to all other payments due to Suzlon as described in this Article 3 (including, in addition to the Contract Price), Owner shall also reimburse Suzlon for Suzlon's actual and reasonable
costs for the installation and Mechanical Completion of the WTGs (including, without limitation, the actual and reasonable costs from Suzlon's vendors, subcontractors and suppliers, all applicable
Taxes, insurance, permitting and other out-of-pocket third party costs and expenses), plus a markup of *** percent (***%) (other than such insurance costs, which shall have a
*** percent (***%) markup) on the lower of: (x) the Price Estimate as to such costs and (y) the actual costs (or, in the event there is no Price Estimate as to such costs, the applicable
markup shall be taken on such actual costs). Further, if Owner requests Suzlon to install and Mechanically Complete any WTGs, Owner must also elect to have Suzlon deliver such WTGs to the
corresponding Project Site. 

43

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

   
        3.4    Payment for the Achievement of Milestones and Reimbursable Expenses.    Except as described in
Section 3.4(d) below, Owner shall pay to Suzlon the Milestone Payments and Reimbursable Expenses in the following manner: 

        (a)   Suzlon
shall, no more frequently than twice a month, prepare and submit to Owner an application for payment specifying 1) each Milestone which has been completed
and/or Reimbursable Expenses which have been incurred (including a description of the WTGs to which they apply) and for which payment is then being requested, 2) the aggregate amount of the
payment then being requested, and 3) any applicable bills of lading or "ex works certificates" and/or the documentation (which shall include for "technical advisor assistance", timesheets
executed by Owner's project manager) supporting the Reimbursable Expenses (each, an "Application for Payment"). 

        (b)   Within
ten (10) Business Days after the receipt of each Application for Payment, Owner shall (A) review the Application for Payment to certify completion
of the relevant Milestone(s) and/or the documentation supporting the Reimbursable Expenses, and (B) issue to Suzlon a written "Certificate for Payment" for such amount as Owner determines is
properly due to Suzlon. If the amount so determined by Owner is less than the amount requested by Suzlon in the Application for Payment, Owner's Certificate for Payment shall indicate the specific
reasons for so withholding all or a portion of the Milestone Payment and/or Reimbursable Expenses. If Owner determines that a portion of the Milestone Payment and/or Reimbursable Expenses is not due,
Owner shall nevertheless approve payment for the remaining portion of the Application for Payment. If Owner fails to issue a Certificate for Payment within fifteen (15) Business Days after
receipt of the corresponding Application for Payment, the entire amount provided in such Application for Payment shall nevertheless be paid by the date specified in Section 3.4(c); provided
however, that such payment shall be without prejudice to any other rights to remedies Owner may have under this Agreement. 

        (c)   Except
as otherwise expressly provided in Footnotes 2 and 3 to this Agreement, within fifteen (15) Business Days after receipt of each Application for Payment,
Owner shall pay directly to the account of Suzlon, as identified in Exhibit C of this Agreement, the amount due with respect to each such Application for Payment. 

        (d)   Owner
acknowledges and agrees that the above procedures do not apply to the Third 2008 Milestone Payment, the Third 2009 Milestone Payment or the Fourth 2009 Milestone
Payment, which payments shall be due on the dates described in Section 3.2(a) without an Application for Payment. 

        (e)   In
the event the Final Payment is payable as to a Project as a result of the occurrence of an Alternate Final Milestone, Owner shall be entitled to "holdback" from the
Final Payment (the "Punch List Holdback") an amount determined as follows: 

        (i)    In
the event there is a Punch List for such Project as of the date of such Alternate Final Milestone, an amount equal to the lesser of (I) (x) *** U.S. Dollars
($***) multiplied by (y), the number of WTGs at such Project, or (II) the dollar amount, if any, that has been mutually assigned by the Parties to complete such Punch List; or 

44

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

        (ii)   In
the event there is no Punch List for such Project as of the date of such Alternate Final Milestone, an amount equal to (x) *** U.S. Dollars ($***) multiplied
by (y), the number of WTGs at such Project. 

Upon
achievement of Final Completion as to such Project, Owner shall pay Suzlon the Punch List Holdback, if any. 

        3.5    Ability
to Stop Work for Failure to Pay.    Should Owner fail to pay any amount to Suzlon when the same is due
(including, without limitation, the Third 2008 Milestone Payment, the Third 2009 Milestone Payment or the Fourth 2009 Milestone Payment), Suzlon may, without prejudice to any other rights to remedies
it may have under this Agreement, stop its performance of the Work until payment of the amount owing has been received by Suzlon. Any monetary or schedule impact to Suzlon as a result of any such work
stoppage shall be borne by Owner alone (and shall be implemented by an amendment to this Agreement reflecting Suzlon's reasonable costs incurred as a result of such stoppage and any reasonable
modifications to the relevant schedules as a result of the stoppage). The terms of this Section 3.5, however, shall not apply to any amount which has not been paid to Suzlon by reason of a
dispute raised by Owner in good faith as to such amount; provided, however, that Owner's dispute of such amount shall not be deemed raised in good faith if, inter alia, Owner fails to provide a
written report to Suzlon (a) within fifteen (15) Business Days after Owner's receipt of the Application for Payment (or, as applicable, the Suzlon invoice) relating to such amount, and
(b) detailing the reasons for Owner's dispute of such amount. 

        3.6    Interest
on Late Payments.    Payments due under this Agreement, but which remain unpaid past the date due for
payment (including any amounts withheld which are later determined to have been improperly withheld), shall bear interest from the date due until paid at the Interest Rate. 

        3.7    Taxes.    Suzlon
shall be responsible for paying all non-United States and non-Canadian
taxes, all United States import taxes and duties, and all of Suzlon's income taxes incurred in connection with Suzlon's performance of the Work or Delivery of the WTGs. All other Taxes incurred in
relation to the Work, any Project, and/or the performance of the parties' duties and obligations under this Agreement (whether in the nature of sales, excise, use or otherwise) shall be borne and paid
by Owner. 

ARTICLE 4  

 MODIFIED OBLIGATIONS  

        4.1    Scope
of the Modified Obligations.    (a)    In the event (i) Owner fails to timely issue an NTP
as provided in Section 2.3 for any reason other than a Suzlon Default or (ii) Definitive Agreements are not executed within the twenty (20) day period referenced in
Section 2.4(a) for any reason other than a Suzlon Default, the Parties' rights, duties and obligations under this Agreement with respect to the corresponding WTGs shall thereupon automatically
and immediately be amended to reflect the following terms and provisions: notwithstanding anything to the contrary contained in this Agreement, Suzlon's scope of Work for such WTGs shall be limited to
the design and manufacturing of such WTGs, the Delivery of such WTGs (provided, 

45

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

however,
the WTG components manufactured outside the continental United States shall be only Delivered to a Gulf Port), and the Commissioning of such WTGs, all in accordance with the terms and
provisions of this Agreement (including, without limitation, the terms and provisions of Exhibit G attached hereto); provided, however, the Milestone payment schedule for such WTGs shall be
that set forth in the following Section 4.1(b) in lieu of the Milestone payment schedule provided in Section 3.2(a), (collectively, the "Modified Obligations"). 

        (b)   Under
the Modified Obligations, Owner shall remain responsible for payment of the full Contract Price as described in Article 3 hereof; provided, however, that
the Milestones and the corresponding Milestone Payments shall be deemed revised to reflect the following: 

	Milestone	 	WTGs to Which

Payment Applies	 	Milestone Payment
	

Execution of this Agreement	
 	

2008 WTGs	
 	

*** U.S. Dollars ($***), representing *** percent (*** %) of the Total 2008 Contract Price, plus the LVRT Fee for all 2008 WTGs (the "Third 2008 Milestone Payment")
	

***	
 	

2009 WTGs	
 	

*** U.S. Dollars ($***), representing *** percent (*** %) of the Total 2009 Contract Price (the "Third 2009 Milestone Payment")
	

***	
 	

2009 WTGs	
 	

*** U.S. Dollars ($***), representing *** percent (***%) of the Total 2009 Contract Price, plus the LVRT Fee for all 2009 WTGs and (if applicable) the Climb-Assist Fee for all 2009 WTGs (provided,
however, that any Climb-Assist Election issued before this date with respect to 2009 WTGs must be accompanied by the Climb-Assist Fee for all the 2009 WTGs) (the "Fourth 2009 Milestone Payment")
	

Date that bills of lading have been issued for all Major Components of a WTG (however, as to the Major Components which are	
 	

All WTGs	
 	

*** percent ***%) of the applicable Contract Price for each WTG (i.e., pro rate the payment for each WTG) (the "Bill of Lading/Ex Works

46

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

	Milestone	 	WTGs to Which

Payment Applies	 	Milestone Payment
	

manufactured within the continental United States, it shall be the date an "ex works certificate" is issued and not a bill of lading)	
 	

 	
 	

Milestone Payment")
	

Earlier of (i) delivery of all Major Components of a WTG to a Project Site, or (ii) fourteen (14) days after Delivery of such Major Components3	
 	

All WTGs	
 	

*** percent (***%) of the applicable Contract Price for each WTG (i.e., pro rate the payment for each WTG)
	

Earlier of (i) completion of Commissioning of such WTG, or (ii) sixty (60) days after the later of (x) Delivery of all Major Components of such WTG (plus any Suzlon Storage Days) and (y) the Delivery Deadline of such WTG	
 	

All WTGs	
 	

*** percent (***%) of the applicable Contract Price (i.e., pro rate the payment for each WTG)
	

Earlier of (i) Final Completion with respect to a Project, or (ii) one hundred twenty (120) days after the later of (x) Delivery of all Major Components of all WTGs which will comprise a Project (plus any Suzlon Storage Days) and (y) the last
Delivery Deadline of any WTG which will comprise a Project (the achievement of such Milestone under clause (ii) being an "Alternate Final Milestone")	
 	

All WTGs	
 	

*** percent (***%) of the applicable Contract Price (prorated for each Project Site, which is determined on the basis of the number of WTGs at each such Project Site) (the "Final Payment"); provided in the event of an Alternate Final Milestone, such
Milestone Payment shall be the Final Payment minus the Punch List Holdback applicable to such Project, as further described in Section 3.4(e))
	

Final Completion with respect to a Project	
 	

All WTGs	
 	

Punch List Holdback applicable to such Project Site

3 NOTE: If this Milestone occurs prior to the first day of the month immediately preceding the month in which the Delivery Deadline for such WTG occurs, then this
Milestone Payment shall be payable on the later of (x) such first day of the month immediately preceding the month in which the Delivery Deadline for such WTG occurs or (y) the date specified in
Section 3.4(c) as to the Application for Payment for such Milestone.

47

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

        4.2    Continuing
Attempts as to Definitive Agreements.    Even though WTGs may be subject to the Modified Obligations,
the Parties shall nevertheless exert their respective best good faith efforts to prepare, execute and deliver (or arrange for the execution and delivery) of Definitive Agreements with respect to such
WTGs (the preparation of which shall be in accordance with the terms of Section 2.4 of this Agreement using the form of Definitive Agreements attached hereto). Except as otherwise expressly
provided herein, upon execution of such Definitive Agreements, the terms of this Agreement, as they relate to the WTGs that are addressed in such Definitive Agreements, shall thereupon automatically
be deemed terminated, of no further force or effect, and superseded by the terms of the Definitive Agreements. In confirmation and furtherance thereof, the Parties acknowledge and agree that (except
as otherwise expressly provided herein) this Agreement shall have no bearing, application or binding effect, whether legal or otherwise, upon any WTGs that are addressed in any executed Definitive
Agreements (or with respect to any rights, remedies or obligations of the Parties with respect to such WTGs). 

ARTICLE 5  

 LIMITATION OF LIABILITY  

        5.1    Aggregate
Liquidated Damages Cap.    (a)    Notwithstanding anything to the contrary contained in this
Agreement: 

        (i)    Suzlon's
aggregate liability for all Delivery Liquidated Damages and Commissioning Liquidated Damages for any individual WTG shall be limited to a maximum of
(x) *** percent (***%) of the 2008 Contract Price (as to any individual 2008 WTG), or (y) *** percent (***%) of the 2009 Contract Price (as to any individual 2009 WTG); 

        (ii)   Suzlon's
aggregate liability for PTC Liquidated Damages for all 2008 WTGs shall not exceed the 2008 PTC LD Cap; and 

        (iii)  Suzlon's
aggregate liability for PTC Liquidated Damages for all 2009 WTGs shall not exceed the 2009 PTC LD Cap. 

        (b)   Notwithstanding
the foregoing or anything to the contrary contained in this Agreement, Suzlon's aggregate liability for any and all Delivery Liquidated Damages,
Commissioning Liquidated Damages, PTC Liquidated Damages, V3 Liquidated Damages, GL Liquidated Damages, Power Curve Liquidated Damages and Measured Average Availability Liquidated Damages for all WTGs
shall not exceed an amount equal to fifty percent (50%) of the Contract Price (the "Aggregate LD Cap"). 

        (c)   Upon
execution of each set of Definitive Agreements, 

        (i)    the
2008 PTC LD Cap and/or the 2009 PTC LD Cap (as applicable) shall thereupon automatically be deemed reduced by the amount specified in each such TSA or TSIA as the
"PTC LD Cap" thereunder; and 

48

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

        (ii)   the
Aggregate LD Cap shall thereupon automatically be deemed reduced by the amount specified in each such TSA or TSIA as the "Aggregate LD Cap" thereunder. 

        5.2    Overall
Limitation of Liability.    (a)    Notwithstanding anything to the contrary contained in this
Agreement, in no event shall Suzlon, its parent company or Affiliates, be liable, alone or in the aggregate, to Owner for any damages, claims, demands, suits, causes of action, losses, costs, expenses
and/or liabilities related in any manner to this Agreement (collectively, "Losses") in excess of an amount equal to *** percent (***%) of the Liability Cap, regardless of whether such liability arises
out of breach of contract, guarantee or warranty, tort, product liability, indemnity, contribution, strict liability or any other legal theory; provided, however: 

        (i)    the
Liability Cap shall not apply to, and no credit shall be issued against the Liability Cap for Suzlon's indemnity obligations set forth in Article 6 below
solely as they relate to claims by third parties for bodily injury or property damage; and 

        (ii)   the
liability of Suzlon, its parent company and their Affiliates for Losses related solely to Suzlon's indemnity obligations under Article 7 (the "IPR
Liability") shall not be subject to the aforementioned Liability Cap, but such IPR Liability shall in no event be in excess of an amount equal to (x) *** percent (***%) of the Liability Cap,
minus (y) the aggregate amount of all Losses for which Suzlon, its parent company and their Affiliates are liable (other than pursuant to the terms of Article 7). 

For
purposes of this Agreement, the "Liability Cap" means an amount equal to the sum of (x) the Contract Price, (y) the LVRT Fee for all WTGs, and (z) the Climb-Assist Fee for all
WTGs for which the Climb-Assist System has been included; provided such amount shall be reduced: (1) by the portion of the Contract Price applicable to the WTG purchases cancelled pursuant to
Section 8.5, and (2) by any amount paid by any contractor, subcontractor, consultant, vendor, supplier or agent of Suzlon to Owner by reason of any claim made by Owner against any such
parties in relation to this Agreement or the work or services provided (or to be provided) by any such parties in relation to this Agreement. In addition, notwithstanding the foregoing, upon execution
of each set of Definitive Agreements, the Liability Cap hereunder shall thereupon automatically be deemed reduced by the amounts specified in each TSA or TSIA as the (x) "contract price"
thereunder, (y) the LVRT Fee for all WTGs thereunder, and (z) the Climb-Assist Fee for all WTGs thereunder for which the Climb-Assist System has been included. For the sake of clarity,
any liability of Suzlon which accrues under any executed Definitive Agreements shall not apply against the Liability Cap. 

        (b)   Notwithstanding
the foregoing or anything to the contrary contained in this Agreement, to the extent Suzlon is liable for Delivery Liquidated Damages, Commissioning
Liquidated Damages, PTC Liquidated Damages, V3 Liquidated Damages, GL Liquidated Damages, Power Curve Liquidated Damages and/or Measured Average Availability Liquidated Damages pursuant to this
Agreement, as to each set of executed Definitive Agreements (if and when executed), that portion of such liquidated damages which is equivalent to the Liquidated Damages Share corresponding to each
such set of Definitive Agreements (i) shall be subject to the "liability caps" under each such set of Definitive Agreements once executed, and (ii) shall not apply to or be credited
against the Liability Cap provided in this Agreement after execution 

49

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

of
such corresponding set of Definitive Agreements (i.e., for the sake of clarity, if Suzlon is liable for liquidated damages under this Agreement, the "limitations of liability" under each such set
of executed Definitive Agreements and not those in this Agreement (such as the Liability Cap), shall apply to the Liquidated Damages Share applicable to each such set of Definitive Agreements). For
the purposes of this Amendment, the term "Liquidated Damages Share" means, as to any executed set of Definitive Agreements, an amount equal to the sum of: 

        (i)    The
Delivery Liquidated Damages, Commissioning Liquidated Damages, PTC Liquidated Damages, Power Curve Liquidated Damages and/or Measured Average Availability Liquidated
Damages, if any, that have accrued as to WTGs covered by such executed set of Definitive Agreements; 

        (ii)   The
V3 Liquidated Damages, if any, divided by the number of WTGs actually purchased pursuant to this Agreement, multiplied by the number of WTGs addressed in such
executed set of Definitive Agreements; and 

        (iii)  The
GL Liquidated Damages, if any, divided by the number of WTGs actually purchased pursuant to this Agreement, multiplied by the number of WTGs addressed in such
executed set of Definitive Agreements 

        5.3    Consequential
Damages.    Notwithstanding anything to the contrary contained in this Agreement (other than the last
sentence of this Section), Owner and Suzlon waive all claims arising in connection with this Agreement against each other (and against each other's parent company, Affiliates, contractors,
subcontractors, consultants, vendors, suppliers and agents) for any consequential, incidental, indirect, special, exemplary or punitive damages (including, but not limited to, loss of actual or
anticipated profits, revenues or product; revenue loss by reason of shutdown or non-operation; increased expense of borrowing or financing; or loss of use or productivity), and regardless
of whether any such claim arises out of breach of contract or warranty, tort, product liability, indemnity, contribution, strict liability or any other legal theory. Any consequential, incidental,
indirect, special, exemplary or punitive damages incurred by Suzlon or Owner in relation to a third party in connection with this Agreement shall, for all purposes of this Agreement, be deemed
consequential, incidental, indirect, special, exemplary or punitive damages in relation to any claim brought by Suzlon or Owner against the other Party to this Agreement. Nothing in this
Section 5.3 shall be deemed to apply to any Delivery Liquidated Damages, Commissioning Liquidated Damages, PTC Liquidated Damages, V3 Liquidated Damages, GL Liquidated Damages, Power Curve
Liquidated Damages or Measured Average Availability Liquidated Damages. 

        5.4    Effect
of Definitive Agreements.    Nothing in this Article 5 or in Section 11.10 is intended to
limit or supersede any liability, remedy or recourse provided for or existing under any executed Definitive Agreements; it being agreed that this Agreement and all executed Definitive Agreements shall
be deemed and treated as separate and distinct agreements. 

        5.5    Releases
Valid in All Events.    Releases, disclaimers, and limitations on liability expressed in this Agreement
shall apply even in the event of the negligence, strict liability, fault, or breach of contract (including other legal bases of responsibility such as fundamental breach) of the Party whose liability
is released, disclaimed, or limited. 

50

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 
ARTICLE 6  

 MUTUAL INDEMNITY  

        6.1    Mutual
Indemnity.    Owner, as one Party, and Suzlon, as the other Party, agree to defend, indemnify and hold each
other, and each other's lenders, parent company, Affiliates, officers, directors, agents and employees, harmless from and against any claims, losses, damages or liabilities (including, but not limited
to, reasonable attorneys' fees and court costs) on account of any claim by a third party (including contractors, subcontractors, consultants, vendors, suppliers and agents of a Party) for bodily
injury or property damage against the indemnified Party caused by the negligent act or omission, or willful misconduct, of the indemnifying Party or the indemnifying Party's employees, contractors,
subcontractors or agents, in connection with the performance of their respective obligations under this Agreement. These indemnification obligations shall survive the termination or expiration of this
Agreement. Notwithstanding the foregoing, the defense, indemnity and hold harmless obligations in this Section 6.1 shall not apply to damage or loss to any property which is part of a Project
(or is to be incorporated into a Project). 

        6.2    Indemnification
Rights Not Abridged.    The indemnification obligations contained in Section 6.1 shall not
be construed so as to negate, abridge, or reduce other rights or obligations of indemnity that would otherwise exist as to an indemnified Party hereunder. In claims against a Party which are
indemnified pursuant to the indemnifications contained in Section 6.1 and which are brought by an employee of the indemnifying Party, a subcontractor of the indemnifying Party, or anyone
employed by them, the indemnification contained in Section 6.1 shall not be limited (i) by a limitation on the amount or type of damages, compensation, or benefits payable by or for the
indemnifying Party, or a subcontractor of the indemnifying Party, under workers' or workmen's compensation acts, disability benefit acts, or other employee benefit acts, or (ii) pursuant to any
common law or case law. 

ARTICLE 7  

 INTELLECTUAL PROPERTY  

        7.1    Indemnity
Against Infringement.    Suzlon shall indemnify and keep indemnified and hold harmless Owner and its
lenders, parent company, Affiliates, officers, directors, agents and employees, from and against all claims, liabilities, losses and damages asserted by any third party person, together with all costs
and expenses relating thereto (including reasonable legal fees), based upon any claim of infringement or misappropriation of any patent or other license or right to intellectual property (whether by
way of patent, copyright, mask work right, trade secret, trademark or otherwise) resulting from the manufacture, offer for sale, sale, supply, or importation of the WTGs, or any part or component
thereof, or their use by Owner as set forth in this Agreement or any Definitive Agreements; provided, however, that Suzlon shall not be obligated to provide an indemnity against infringement or
misappropriation resulting from the use of the WTGs, or any part, component or process thereof, by Owner as set forth in this Agreement or any Definitive Agreements to the extent such infringement or
misappropriation arose or resulted from Owner's failure to erect, Mechanically Complete (unless erection and/or Mechanical Completion services were provided by Suzlon pursuant to this Agreement),
operate, 

51

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

or
maintain (unless the applicable maintenance services were provided by Suzlon pursuant to this Agreement) such WTGs in accordance with the Installation Manual, Operation Manual and Service Manual.
Each Party agrees to notify the other as soon as possible of any material matters with respect to which the foregoing indemnity may apply and of which the notifying Party has knowledge. Subject to the
preceding terms, if notified in writing of any action or claim for which Suzlon is to provide an indemnity under this Section 7.1, Suzlon shall, without limitation, defend such action or claim
at its expense and pay the cost and damages and attorneys' fees awarded against Owner in such action or claim; provided, that Suzlon shall have the right to control the defense (including selection of
defense counsel) and settlement of all such actions or claims. 

        7.2    Treatment
of Infringing Equipment.    If an order by any court of competent jurisdiction shall be obtained against
the sale or delivery to Owner, or Owner's use or operation of, the WTGs or any part or component thereof or process used therein by reason of Suzlon's alleged infringement of any intellectual property
right of any party (whether by reason of a patent, copyright, mask work right, trade secret, trademark or other license or right), Suzlon shall first be afforded a reasonable opportunity, at its
expense but without limiting its indemnification obligations under Section 7.1, to diligently seek the discharge of any such order as aforesaid, and at Suzlon's election to forthwith: 

	(i)
	at
a commercially reasonably time (taking into consideration Owner's operation of any applicable WTG), modify the WTGs so that they become non-infringing;

	(ii)
	procure
for Owner the right to use, or continue to use, the WTGs and the infringing equipment, component or process; or

	(iii)
	substitute
for any infringing equipment, component or process, other non-infringing equipment, component or process having the capabilities, quality, utility and
workmanship which otherwise satisfy Suzlon's obligations under this Agreement; 

        except
to the extent such alleged infringement arose or resulted from Owner's failure to erect, Mechanically Complete (unless erection and/or Mechanical Completion services were provided
by Suzlon pursuant to this Agreement), operate, or maintain (unless the applicable maintenance services were provided by Suzlon pursuant to this Agreement) such WTGs in accordance with the
Installation Manual, Operation Manual and Service Manual. Suzlon's replacement or modification of infringing equipment, parts, components or processes pursuant to this Section 7.2 must conform
to the Technical Specifications, and may not reduce the power rating of the WTGs or materially increase the operating costs of the WTGs. 

ARTICLE 8  

 DEFAULT AND REMEDIES AND TERMINATION  

        8.1    Termination
by Owner for Cause.    The occurrence of any one or more of the following matters constitutes a default
by Suzlon under this Agreement (a "Suzlon Default"): 

52

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

   
        (a)   Suzlon becomes insolvent or generally fails to pay, or admits in writing its inability or unwillingness to pay, its debts as they become due; 

        (b)   Suzlon
makes a general assignment for the benefit of its creditors; 

        (c)   Suzlon
shall commence or consent to any case, proceeding or other action (a) seeking reorganization, arrangement, adjustment, liquidation, dissolution or
composition of Suzlon or of Suzlon's debts under any Law relating to bankruptcy, insolvency, reorganization or relief of debts, or (b) seeking appointment of a receiver, trustee or similar
official for Suzlon or for all or any part of Suzlon's property; 

        (d)   any
case, proceeding or other action against Suzlon shall be commenced (a) seeking to have an order for relief entered against Suzlon as debtor,
(b) seeking reorganization, arrangement, adjustment, liquidation, dissolution or composition of Suzlon or Suzlon's debts under any Law relating to bankruptcy, insolvency, reorganization or
relief of debtors, or (c) seeking appointment of a receiver, trustee, or similar official for Suzlon or for all or any part of Suzlon's property; and such case, proceeding or action is not
dismissed within sixty (60) days thereafter; 

        (e)   the
material breach of any representation or warranty made by Suzlon herein which prevents Suzlon from performing hereunder; 

        (f)    Suzlon
attempts to assign, convey or transfer this Agreement or any interest herein without Owner's prior written consent; 

        (g)   Suzlon
fails to make any payment to Owner when due pursuant to the terms of this Agreement, and such failure continues for five (5) Business Days following
Suzlon's receipt of written notice from Owner to cure such failure (provided, however, the terms of this Section 8.1(g) shall not apply to any amount which has not been paid to Owner by reason
of a dispute raised by Suzlon in good faith as to such amount); 

        (h)   the
Delivery Liquidated Damages that have accrued with respect to a WTG are equivalent to the corresponding Delivery LD Cap, and the Delivery delay with respect to such
WTG is thereafter continuing; 

        (i)    the
Commissioning Liquidated Damages that have accrued with respect to a WTG are equivalent to the corresponding Commissioning LD Cap, and the Commissioning delay with
respect to such WTG is thereafter continuing; 

        (j)    Suzlon
fails to observe or perform in any material respect any other material covenant, agreement, obligation, duty or provision of this Agreement, and such failure
continues for thirty (30) days after Suzlon's receipt of written notice thereof from Owner; provided, however, if such failure cannot with due diligence be remedied by Suzlon within such thirty
(30) day period, and Suzlon shall have diligently prosecuted the remedying of such failure within such thirty (30) days, such period shall be extended by such additional time period as
may be reasonably required by Suzlon to cure such failure; 

53

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

        (k)   (a)
one or more defaults by Suzlon have occurred under two or more sets of executed Definitive Agreements for different Projects (i.e., in each instance, there has been
a breach by Suzlon under such Definitive Agreements and the applicable cure period under the corresponding Definitive Agreements has lapsed), (b) such default(s) relate(s) to twenty
(20) or more WTGs, and (c) after the occurrence or lapse of the circumstances described in the preceding clauses (a) and (b), Suzlon fails to cure such default(s) within ten
(10) Business Days after receipt of written notice from Owner specifying that Owner will declare a default under this Section 8.1(k) unless the default(s) under the Definitive Agreements
are cured within such ten (10) day time period; or 

        (l)    the
Suzlon Guarantor has breached the terms of the Suzlon Parent Guarantee. 

        8.2    Remedies
Upon Suzlon Default.    Upon the occurrence of a Suzlon Default, Owner may, without prejudice to any other
right or remedy Owner may have under this Agreement or at law and/or in equity, terminate this Agreement (but, in reference to a Suzlon Default specified under Section 8.1(h) or 8.1(i), only as
to the WTG(s) to which such default applies) and, subject to Article 5 of this Agreement, seek recovery of any damages resulting therefrom. 

        8.3    Termination
by Suzlon for Cause.    The occurrence of any one or more of the following matters shall constitute a
default by Owner under this Agreement (an "Owner Default"): 

        (a)   Owner
becomes insolvent or generally fails to pay, or admits in writing its inability or unwillingness to pay, its debts as they become due; 

        (b)   Owner
makes a general assignment for the benefit of its creditors; 

        (c)   Owner
shall commence or consent to any case, proceeding or other action (a) seeking reorganization, arrangement, adjustment, liquidation, dissolution or
composition of Owner or of Owner's debts under any Law relating to bankruptcy, insolvency, reorganization or relief of debts, or (b) seeking appointment of a receiver, trustee or similar
official for Owner or for all or any part of Owner's property; 

        (d)   any
case, proceeding or other action against Owner shall be commenced (a) seeking to have an order for relief entered against Owner as debtor, (b) seeking
reorganization, arrangement, adjustment, liquidation, dissolution or composition of Owner or Owner's debts under any Law relating to bankruptcy, insolvency, reorganization or relief of debtors, or
(c) seeking appointment of a receiver, trustee, or similar official for Owner or for all or any part of Owner's property; and such case, proceeding or other action is not dismissed within sixty
(60) days thereafter; 

        (e)   the
material breach of any representation or warranty made by Owner herein which prevents Suzlon from performing hereunder; 

        (f)    Owner
attempts to assign, convey or transfer this Agreement or any interest herein contrary to or in violation of the terms of Section 11.2; 

54

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

        (g)   Owner
fails to make any payment to Suzlon when due pursuant to the terms of this Agreement, and such failure continues for five (5) Business Days following
Owner's receipt of written notice from Suzlon to cure such failure (provided, however, the terms of this Section 8.3(g) shall not apply to any amount which has not been paid to Suzlon by reason
of a dispute raised by Owner in good faith as to such amount; provided, however, that Owner's dispute of such amount shall not be deemed raised in good faith if, inter alia, Owner fails to provide a
written report to Suzlon (a) within fifteen (15) Business Days after Owner's receipt of the Application for Payment (or, as applicable, the Suzlon invoice) relating to such amount, and
(b) detailing the reasons for Owner's dispute of such amount); 

        (h)   Owner
fails to observe or perform in any material respect any material covenant, agreement, obligation, duty or provision of this Agreement (excluding payment
obligations, which are addressed in the preceding subsection (g)), and such failure continues for thirty (30) days after Owner's receipt of written notice thereof from Suzlon; provided,
however, if such failure cannot with due diligence be remedied by Owner within such thirty (30) day period, and Owner shall have diligently prosecuted the remedying of such failure within such
thirty (30) days, such period shall be extended by such additional time period as may be reasonably required by Owner to cure such failure; or 

        (i)    the
Owner Guarantor has breached the terms of the Owner Parent Guarantee. 

        8.4    Remedies
Upon Owner Default.    Upon the occurrence of an Owner Default, Suzlon may, without prejudice to any other
right or remedy Suzlon may have under this Agreement or at law and/or in equity, terminate this Agreement and, subject to Article 5 of this Agreement, seek recovery of any damages resulting
therefrom. 

        8.5    Termination
for Convenience by Owner.    (a)Owner may terminate this Agreement for convenience as to any WTG by
providing Suzlon written notice of such desire on or before the date that is *** months prior to the Delivery Deadline applicable to any such WTG. To be effective, any such notice by Owner shall (as
to each cancelled WTG) be accompanied by an amount equal to (i) the Cancellation Fee, less (ii) all amounts paid by Owner prior to such date with respect to such WTG (such net amount to
be paid to Suzlon as to each cancelled WTG being the "Cancelled Amount"). In the event of any such termination, Suzlon shall exercise commercially reasonable efforts to resell such WTGs to third
parties during the 365 day period after receipt of any such notice from Owner. 

        (b)   For
the purposes of this Section 8.5, the "Cancellation Fee" for each WTG shall be as follows: 

	Date of Suzlon's receipt of notice of WTG

cancellation	 	Cancellation Fee for each

WTG
	

On or prior to *** for 2008 Extended Delivery WTGs and 2009 WTGs:	
 	

*** percent (***%) of the 2008 Contract Price or 2009 Contract Price, as applicable.

55

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

	Between and including *** and *** for 2008 Extended Delivery WTGs and 2009 WTGs:	 	*** percent (***%) of the 2008 Contract Price or 2009 Contract Price, as applicable.
	

Between and including the Effective Date and the date which is *** months prior to the Delivery Deadline of the applicable 2008 WTGs (other than 2008 Extended Delivery WTGs):	
 	

*** percent (***%) of the 2008 Contract Price.
	

Between and including *** and the date which is *** months prior to the Delivery Deadline of the applicable 2008 Extended Delivery WTGs and 2009 WTGs:	
 	

*** percent (***%) of the 2008 Contract Price or 2009 Contract Price, as applicable.

        (c)   As
to any WTGs Suzlon is unable to resell during such 365 day period, Suzlon shall be entitled to retain the applicable Cancelled Amount. 

        (d)   As
to those WTGs, if any, Suzlon does in fact resell (i.e., Suzlon receives a fully binding purchase commitment from a bona-fide purchaser) during the
365 day period following receipt of the notice of termination for convenience, the following shall occur: 

	(i)
	Suzlon
shall reimburse Owner for each such resold WTG an amount equal to (x) the applicable Cancelled Amount, less (y) Remarketing Costs and the Lost Purchase Price.
However, if the amount calculated pursuant to clause (y) exceeds the applicable Cancelled Amount, Owner shall promptly pay such excess to Suzlon.

	(ii)
	"Remarketing
Costs" shall mean all reasonable costs incurred by Suzlon in reselling a WTG for which Owner has cancelled its purchase, including, without limitation, extra handling,
storage, reselling, marketing and legal costs. "Lost Purchase Price" shall be the amount, if any, by which the applicable Contract Price to have been paid by Owner for a cancelled WTG exceeds the
purchase price for which a bona-fide purchaser buys such WTG. 

Owner
may propose potential purchasers for any cancelled WTGs, which purchasers Suzlon shall consider in good faith (but with whom Suzlon shall not be obligated to contract). 

In
confirmation of the preceding terms of this Section, this Agreement shall remain in full force and effect as to any WTG for which Suzlon has not received Owner's written notice to Suzlon by the
date that is *** prior to the Delivery Deadline of such WTG. 

        8.6    Actions
Upon Termination.    Upon termination of this Agreement, Suzlon will (a) cease operations as
directed by Owner, (b) take all actions necessary for the protection and preservation of all equipment, materials, parts, supplies and the Work (in whatever stage of completion), and
(c) cease entering into subcontracts and purchase orders. 

56

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 
ARTICLE 9  

 REPRESENTATIONS AND WARRANTIES  

        9.1    Owner
Representations and Warranties.    Owner represents and warrants to Suzlon as follows: 

        (a)    Due
Organization; Good Standing; Qualified to Do Business.    Owner is a corporation duly organized, validly
existing and in good standing under the laws of the State of Delaware. 

        (b)    Due
Authorization.    The execution, delivery and performance of this Agreement by Owner have been duly authorized
by all necessary corporate action on the part of Owner and do not and will not require the consent of any trustee or holder of any indebtedness or other obligation of Owner or any other party to any
other agreement with Owner. 

        (c)    Execution
and Delivery.    This Agreement has been duly executed and delivered by Owner. This Agreement constitutes
the legal, valid, binding and enforceable obligation of Owner, except to the extent that its enforceability may be limited by bankruptcy, insolvency, reorganization, moratorium or other similar laws
affecting the rights of creditors generally or by principles of equity. 

        (d)    Governmental
Approvals.    No governmental authorization, approval, order, license, permit, franchise or consent,
and no registration, declaration or filing with any Governmental Authority is required on the part of Owner in connection with the execution, delivery and performance of this Agreement, except those
which have already been obtained or which Owner anticipates will be timely obtained in the ordinary course of performance of this Agreement. 

        9.2    Suzlon
Representations and Warranties.    Suzlon hereby represents and warrants to Owner as follows: 

        (a)    Due
Organization; Good Standing.    Suzlon is a corporation duly organized, validly existing and in good standing
under the laws of the State of Delaware. 

        (b)    Due
Authorization.    The execution, delivery and performance of this Agreement by Suzlon have been duly authorized
by all necessary corporate action on the part of Suzlon and do not and will not require the consent of any trustee or holder of any indebtedness or other obligation of Suzlon or any other party to any
other agreement with Suzlon. 

        (c)    Execution
and Delivery.    This Agreement has been duly executed and delivered by Suzlon. This Agreement
constitutes the legal, valid, binding and enforceable obligation of Suzlon, except to the extent that its enforceability may be limited by bankruptcy, insolvency, reorganization, moratorium or other
similar laws affecting the rights of creditors generally or by principles of equity. 

        (d)    Governmental
Approvals.    No governmental authorization, approval, order, license, permit, franchise or consent,
and no registration, declaration or filing with any 

57

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

Governmental
Authority is required on the part of Suzlon in connection with the execution, delivery and performance of this Agreement, except those which have already been obtained or which Suzlon
anticipates will be timely obtained in the ordinary course of performance of this Agreement. 

        (e)    Patents,
Licenses, Franchises.    (i)    Suzlon is the holder of all patents, trademarks, service marks,
trade names, copyrights, franchises, governmental consents, licenses, permits or other authorizations required in Suzlon's name to permit it to perform the Work, and operate or conduct its business,
as contemplated by this Agreement or any Definitive Agreements; (ii) Suzlon has and will continue to have all intellectual property rights necessary to allow Owner and its subcontractors to
assemble, use, operate, service, maintain and repair the WTGs (and each component, part and process thereof) without restriction or additional charge (excluding those restrictions and charges set
forth elsewhere in this Agreement and (as applicable) the Modified Obligations or the Definitive Agreements); except to the extent such intellectual property rights are impaired or otherwise adversely
affected by reason of Owner's failure to erect, Mechanically Complete (unless erection and/or Mechanical Completion services were provided by Suzlon pursuant to this Agreement), operate, or maintain
(unless the applicable maintenance services were provided by Suzlon pursuant to this Agreement) such WTGs in accordance with the Installation Manual, Operation Manual and Service Manual; and
(iii) to Suzlon's actual knowledge, neither the WTGs, including any component or part thereof or the processes used herein, nor the process used to manufacture the WTGs, or any component or
part thereof, infringe or misappropriate any patent, copyright, mask work right, trade secret or other intellectual property and/or proprietary right of any third party. 

ARTICLE 10  

 CONFIDENTIALITY  

        10.1    Confidentiality.    (a)    Owner
and Suzlon each agree to keep confidential, and shall not disclose, the
terms and provisions of this Agreement, the Design Materials and, upon receipt from the other Party, any documentation or information (i) which is marked as "proprietary" or "confidential",
(ii) which is supplied orally with a contemporaneous confidential designation, or (iii) which is known by the receiving Party to be confidential or proprietary information or
documentation of the disclosing Party (collectively, the "Confidential Information"). The Parties will grant access to the Confidential Information only to (a) their respective Affiliates, and
to its and their respective employees and authorized contractors, subcontractors, representatives and agents whose access is necessary to fulfill the terms of this Agreement or the Definitive
Agreements executed in connection herewith, and (b) potential investors, lenders and developers in or of a proposed Project, in each case, who shall be bound by the terms and provisions of this
Section; provided that (i) any such access shall be limited to such Confidential Information as any such employee, authorized contractor, subcontractor, representative or agent requires in
order to fulfill the terms of this Agreement or the Definitive Agreements, (ii) any such access shall in no event include any pricing information with respect to this Agreement unless
(x) as to Owner's provision of such access, such access is to Owner's Affiliates, potential investors in or lenders of Owner or potential investors, lenders or developers in or of a proposed
Project, and their respective employees or authorized representatives or agents or (y) as to Suzlon's provision of such access, such access is to Suzlon's Affiliates, 

58

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

potential
investors in or lenders of Suzlon, and their respective employees or authorized representatives or agents and (iii) the Party granting such access makes any third party with which
such Confidential Information is shared subject to a written confidentiality agreement with terms substantially similar to those set forth in this Section, unless such third party has Control over
such Party. Notwithstanding the foregoing, Owner, or any Affiliate or other entity which owns a Project, may also use Confidential Information (excluding pricing information) of Suzlon for the
operation, maintenance and servicing of the WTGs, provided that Owner makes any third party with which such Confidential Information is shared subject to a written confidentiality agreement with terms
substantially similar to those set forth in this Section. Each Party shall be liable for the disclosure of Confidential Information by any of its respective Affiliates, employees, contractors,
subcontractors, representatives or agents. In addition, the Parties shall have no obligation with respect to any Confidential Information which (i) is or becomes publicly known through no act
of the receiving Party, (ii) is approved for release by written authorization of the disclosing Party, (iii) is required to be disclosed by the receiving Party pursuant to legal
requirements applicable to it (e.g., SEC disclosure obligations) or a legal process (so long as the receiving Party uses commercially reasonable efforts to avoid disclosure of such Confidential
Information, and prior to furnishing such Confidential Information, the receiving Party notifies the disclosing Party and gives the disclosing Party the opportunity to object to the disclosure and/or
to seek a protective order), or (iv) has been rightfully furnished to the receiving Party without any restriction on use or disclosure and not in violation of the rights of the other Party. 

        (b)   Notwithstanding
anything to the contrary in this Agreement, if Owner sells all or substantially all of its ownership interests, or all or substantially all of its
assets, to a Competitor or an Affiliate of a Competitor, Owner shall keep confidential the Specified Information of Suzlon vis-a-vis any such Competitor and shall not disclose
any such Specified Information to such Competitor. For purposes of this Agreement, "Specified Information" shall mean the Design Materials, and for a period of two (2) years from the Effective
Date, all pricing information in this Agreement or in any Definitive Agreement. 

        (c)   Nothing
in this Agreement shall bar the right of either Party to seek and obtain from any court injunctive relief against conduct or threatened conduct which violates
this Section. 

ARTICLE 11  

 MISCELLANEOUS PROVISIONS  

        11.1    Waiver.    No
delay or omission by the Parties hereto in exercising any right or remedy provided for herein shall
constitute a waiver of such right or remedy, nor shall it be construed as a bar to or waiver of any such right or remedy on any future occasion. 

        11.2    Successors
and Assigns.    (a)    This Agreement shall be binding upon and shall inure to the benefit of
the successors and permitted assigns of Suzlon and Owner. Neither Suzlon nor Owner may assign, convey or transfer this Agreement, in whole or in part, except upon the prior written consent of the
other Party hereto, which consent shall not be unreasonably withheld or delayed (provided, however, Suzlon acknowledges and agrees that Edison Mission Energy (as Owner under this Agreement) may
assign, convey or transfer this Agreement, in 

59

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

whole
or in part, to any Affiliate of Edison Mission Energy without Suzlon's prior written consent). Notwithstanding the foregoing, and except as otherwise expressly approved in writing by Suzlon, no
assignment, conveyance or transfer of this Agreement, in whole or in part, by Edison Mission Energy shall be effective or otherwise binding unless and until Edison Mission Energy executes and delivers
to Suzlon a guaranty in the form attached hereto as Exhibit E guaranteeing the obligations of the Owner under this Agreement. 

        (b)   If
Owner sells all or substantially all of its assets, it shall simultaneously therewith provide Suzlon with Acceptable Replacement Security unless the purchaser of such
assets, on the date of such sale (i) assumes all of the rights and obligations of the Owner under this Agreement and (ii) has comparable creditworthiness of Edison Mission Energy as of
the Effective Date. 

        11.3    Notices.    Any
notice required or authorized to be given hereunder or any other communications between the
Parties provided for under the terms of this Agreement shall be in writing (unless otherwise provided) and shall be served personally or by reputable express courier service or by facsimile
transmission addressed to the relevant Party at the address stated below or at any other address notified by that Party to the other as its address for service. Any notice so given personally or by
express courier service shall be deemed to have been served and received upon delivery, or attempted delivery, and any notice so given by facsimile transmission shall be deemed to have been served and
received on dispatch. As proof of such service and receipt, it shall be sufficient to produce a receipt showing delivery, or attempted delivery, by personal service or by express courier service, or
an activity report of the sender's facsimile machine showing the correct facsimile number of the Party to whom notice is served and the correct number of pages transmitted. 

        The
Parties' addresses for service are: 

	 	 	To Owner:	 	Edison Mission Energy

18101 Von Karman Avenue, Suite 1700

Irvine, California 92612-1046

Attn: Investment Director

Facsimile: (949) 757-4888

Telephone: (949) 757-2404	 	 
	

 	
 	

with a copy to:	
 	

Edison Mission Energy

18101 Von Karman Avenue, Suite 1700

Irvine, California 92612-1046

Attn: General Counsel

Facsimile: (949) 757-4787

Telephone: (949) 757-2411	
 	

 

60

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

	

 	
 	

To Suzlon:	
 	

Suzlon Wind Energy Corporation

8750 West Bryn Mawr Avenue

Suite 720

Chicago, Illinois 60631

Attn: Chief Executive Officer

Facsimile: (773) 444-0588

Telephone: (773) 328-5077	
 	

 
	

 	
 	

with a copy to:	
 	

Mayer, Brown, Rowe & Maw LLP

71 South Wacker Drive

Chicago, Illinois 60606

Attn: Tim Callahan

Facsimile: (312) 706-9131

Telephone: (312) 701-7204	
 	

 

        11.4    Governing
Law.    This Agreement and all matters arising hereunder or in connection herewith shall be governed by
and construed in accordance with the laws of the State of Illinois, without regard to conflicts of law principles. 

        11.5    Amendments.    This
Agreement may be modified or amended only by an instrument in writing signed by the Parties
hereto. 

        11.6    Attachments
Incorporated.    The recitals on the first few pages of this Agreement, and the Exhibits attached
hereto, are hereby incorporated into and made a part of this Agreement. 

        11.7    Performance
Security.    (a)    As a material inducement to Owner to enter into this Agreement,
(i) Suzlon Energy A/S (the "Suzlon Guarantor") shall guarantee the payment and performance obligations of Suzlon under this Agreement by executing and delivering, upon execution and delivery of
this Agreement, a Guaranty in the form attached hereto as Exhibit D (the "Suzlon Parent Guarantee"), and (ii) Suzlon Energy A/S shall guarantee the payment and performance obligations of
Suzlon under each set of executed Definitive Agreements by executing and delivering, along with the execution of each set of Definitive Agreements, a Guaranty in the form attached as Exhibit D. 

        (b)   As
a further material inducement to Owner to enter into this Agreement, Suzlon shall provide Owner with additional security for the performance of Suzlon's obligations
under this Agreement and the Definitive Agreements, which additional security shall be provided (or increased, as applicable) when Owner pays Suzlon the Third 2008 Milestone Payment, the Fourth 2009
Milestone Payment and any Bill of Lading/Ex Works Milestone Payment (each a "Security Milestone Payment"). When each Security Milestone Payment is made by Owner to Suzlon, *** percent (***%) of such
payment shall, in accordance with the following provisions, be deposited in the following Payment Escrow and/or addressed in the form of the following Suzlon L/C (as the case may be), or a combination
thereof, at Suzlon's discretion (the security so selected by Suzlon, including any combination thereof, being the "Suzlon Security", and the aggregate amount of the Suzlon Security being the
"Retention"): 

61

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

  

	•
	An
escrow (the "Payment Escrow") established pursuant to an escrow agreement in the form attached hereto as Exhibit M with an escrowee mutually acceptable to the
Parties. The funds deposited in the Payment Escrow shall be invested in a manner directed by Suzlon, and all interest thereon shall accrue solely for the benefit of Suzlon. The cost of establishing
and maintaining the Payment Escrow shall be borne and paid by Suzlon. 

and/or 

	•
	One
or more irrevocable letters of credit (i) established at least three (3) Business Days prior to the dates each Security Milestone Payment is due from Owner
to Suzlon (i) in a form attached hereto as Exhibit F, (ii) issued by a financial institution with an S&P rating of "A-" or better or a Moody's rating of
"A-" or better, and (iii) naming the Owner as beneficiary (the "Suzlon L/C"). If Suzlon seeks to increase the face amount of the Suzlon L/C as a result of any upcoming Security
Milestone Payment, at least three (3) Business Days prior to such Security Milestone Payment, Suzlon shall issue replacements or modifications of the Suzlon L/C, which such replacements or
modifications shall increase the face amount of the Suzlon L/C by the amount so desired by Suzlon (which increase, in combination with amounts deposited or to be deposited in the Payment Escrow shall
equal ***percent (***%) of such Security Milestone Payment). Such letters of credit shall have an expiry date no sooner than twelve (12) calendar months after issuance and Suzlon shall furnish
extensions or replacements of the Letter of Credit ten (10) days prior to the expiration thereof from time to time until all of the Retention is to be returned to Suzlon as provided in this
Section 11.7(b). Owner shall have the right to draw against the Suzlon L/C upon the failure or refusal of Suzlon to deliver any applicable extension or replacement of the Suzlon L/C as provided
above. Notwithstanding the foregoing, Owner acknowledges and agrees that Suzlon has the right (in its sole discretion) to provide the required Retention through any combination of the Payment Escrow
and/or the Suzlon L/C, and Owner shall not have the right to draw against the Suzlon L/C for the failure or refusal of Suzlon to deliver any applicable extension or replacement of the same to the
extent
Suzlon is providing the then-required amount of Retention through some combination of the Payment Escrow and/or the Suzlon L/C. In the event of a draw due to the failure or refusal of
Suzlon to deliver any applicable extension or replacement of the applicable Suzlon L/C, Owner shall place and hold the proceeds of such draw in (i) the Payment Escrow or (ii) in the
event the Payment Escrow is not yet established, in an escrow account until such time as (x) the Payment Escrow is established, (y) Owner is entitled to draw upon such funds as provided
herein or (z) Owner is obligated to return to Suzlon the amount of any such draw upon receipt of an extension or replacement of the applicable Suzlon L/C. Any draw made by Owner under a Suzlon
L/C shall not relieve Suzlon of any liabilities, deficiencies, costs, expenses or damages beyond what is drawn under the applicable Suzlon L/C. The cost of establishing and maintaining the Suzlon L/C
shall be borne and paid by Suzlon. 

62

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

The
Parties acknowledge and agree that the Suzlon Security is intended to act as security for Suzlon's obligations under this Agreement and all executed Definitive Agreements. Upon Delivery of all
Major Components of a WTG, the Retention applicable to such WTG shall be released to Suzlon (through automatic withdrawals from the Payment Escrow and/or a reduction in the Suzlon L/C) in an amount
equal to such WTG's pro rata share of the Retention (which pro rata share shall be determined based on the number of WTGs actually purchased pursuant to this Agreement and taking into account those
WTGs whose pro rata share has already been released from the Retention), and shall apply whether the Delivery occurs pursuant to this Agreement or any executed Definitive Agreements. Suzlon shall, in
its discretion, have the right to determine whether the reduction in the Retention upon Delivery shall occur by means of a withdrawal from the Payment Escrow or a reduction in the Suzlon L/C.
Notwithstanding the foregoing, in the event of a Suzlon Default, Owner shall be entitled to draw upon the Retention for actual damages incurred by Owner as a result of such Suzlon Default, including
any amount that constitutes liquidated damages hereunder where Suzlon has not paid such liquidated damages within the time required by this Agreement and such failure to pay has become a Suzlon
Default. Any draw made by Owner upon the Retention shall in no way relieve Suzlon of any of its duties or obligations under this Agreement or any Definitive Agreements (other than the duties and
obligations for which such draw was made). Each Payment Escrow and Suzlon L/C shall contain terms providing for the withdrawal from such Payment Escrow and/or the draw upon or reduction in such Suzlon
L/C (as applicable) in the manner described in this Section 11.7(b). In addition, the Parties acknowledge and agree that, concurrently with the execution of each set of Definitive Agreements,
the Parties will enter into an agreement with the "owner" under such set of Definitive Agreements which details the terms and conditions upon which such "owner" may draw upon the Suzlon Security as
described in this Section 11.7(b). 

        (c)   As
a material inducement to Suzlon to enter into this Agreement and each set of Definitive Agreements, Edison Mission Energy or an Affiliate of Edison Mission Energy
with comparable creditworthiness to Edison Mission Energy as of the Effective Date shall guarantee the payment obligations of the "owner" under each set of executed Definitive Agreements by delivering
one of the following along with the execution and delivery of each set of Definitive Agreements: 

        (i)    A
guaranty executed by Edison Mission Energy or an Affiliate of Edison Mission Energy with comparable creditworthiness to Edison Mission Energy as of the Effective Date
(an "Owner Guarantor") in the form attached hereto as Exhibit E (an "Owner Parent Guarantee"); or 

        (ii)   An
irrevocable letter of credit (a) in the form attached hereto as Exhibit H, (b) issued by a financial institution with an S&P rating of
"A-" or better or a Moody's rating of "A-" or better, (c) naming Suzlon as beneficiary, and (d) in a face amount equal to the balance of the "contract price"
under the corresponding TSA or TSIA (the "Owner's L/C"). The required amount of an Owner's L/C shall be reduced upon the payment by "owner" under such Definitive Agreement to Suzlon of the applicable
Milestone Payments set forth in such Definitive Agreements, such that at any given time, the required face amount of the Owner's L/C shall equal the balance of the "contract price" under the
corresponding TSA or TSIA. Owner covenants and agrees that an Owner's L/C (x) shall permit partial draws, and (y) shall have an expiry date no sooner 

63

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

than
twelve (12) calendar months after issuance (and Owner shall furnish extensions or replacements of such letter of credit ten (10) days prior to the expiration thereof from time to
time prior to payment of the Milestone Payment to be made by "owner" under such Definitive Agreement upon the Final Completion of the applicable Project). Upon payment of the Milestone Payment to be
made by "owner" under a Definitive Agreement upon the Final Completion of the applicable Project, the applicable Owner's L/C shall be returned to Owner. 

An
Owner's L/C shall secure the payment obligations of "owner" under each such set of executed Definitive Agreements. Suzlon shall have the right to draw against an Owner's L/C upon: (i) the
failure of "owner" under a Definitive Agreement to make a Milestone Payment when due under such set of Definitive Agreements or (ii) the failure or refusal of Owner to deliver any applicable
extension or replacement of the applicable Owner's L/C as provided above. In the event of a draw due to the failure of "owner" under a Definitive Agreement to make a Milestone Payment when due, the
proceeds of the draw shall be applied against the applicable Milestone Payment and any costs, expenses and damages incurred by Suzlon as a result of the failure of the "owner" under such Definitive
Agreement to make the applicable Milestone Payment. In the event of a draw due to the failure or refusal of Owner to deliver any applicable extension or replacement of the applicable Owner's L/C,
Suzlon shall place and hold the proceeds of such draw in an escrow account and shall draw upon them as provided herein or return to Owner the amount of any such draw upon receipt of an extension or
replacement of the applicable Owner's L/C or payment of any applicable Milestone Payments. Any draw made by Suzlon under an Owner's L/C shall not relieve "owner" under such Definitive Agreement of any
liabilities, deficiencies, costs, expenses or damages beyond what is drawn under the applicable Owner's L/C. 

        11.8    Entire
Agreement.    The terms and conditions set forth herein and in the Performance Side Letter, together with
those set forth on all Exhibits attached hereto, constitute the complete statement of the agreement between Owner and Suzlon relating to the subject matter hereof. No prior statement or correspondence
shall modify or affect the terms and conditions hereof. Prior representations, promises, warranties or statements by Suzlon or Owner, or by any agent or employee of Suzlon or Owner, that differ in any
way from the terms and conditions hereof shall be given no effect. 

        11.9    Counterparts.    This
Agreement may be executed by the Parties in one or more counterparts, all of which taken
together, shall constitute one and the same instrument. 

        11.10    NO IMPLIED WARRANTIES.    ANY GUARANTIES
AND WARRANTIES SET FORTH IN THIS AGREEMENT ARE SUZLON'S SOLE AND EXCLUSIVE GUARANTIES AND WARRANTIES. SUZLON MAKES NO OTHER GUARANTIES OR WARRANTIES OF ANY KIND WHATSOEVER, EXPRESS, IMPLIED, ORAL,
WRITTEN OR OTHERWISE, INCLUDING, WITHOUT LIMITATION, WARRANTIES OF NON-INFRINGEMENT, TITLE, PATENT, MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE, OR WARRANTIES ARISING BY CUSTOM,
TRADE USAGE, PROMISE, EXAMPLE OR DESCRIPTION, ALL OF WHICH GUARANTIES 

64

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

AND WARRANTIES ARE EXPRESSLY DISCLAIMED BY SUZLON AND WAIVED BY OWNER.

        11.11    Severability.    In
case any provision in this Agreement is held to be invalid, illegal or unenforceable, the
validity, legality and enforceability of the remaining provisions shall not be affected. 

        11.12    Headings.    The
headings and captions used in this Agreement are inserted for reference and convenience only and
the same shall not limit or construe the sections, articles or paragraphs to which they apply or otherwise affect the interpretation thereof. 

        11.13    Signatures.    The
exchange of copies of this Agreement and of signature pages by facsimile or other electronic
transmission shall constitute effective execution and delivery of this Agreement as to the Parties and may be used in lieu of the original Agreement for all purposes. Signatures of the Parties
transmitted by facsimile or other electronic means shall be deemed to be their original signatures for all purposes. 

        11.14    Interpretation.    (a)The
Parties acknowledge and agree that the Definitive Agreements (attached hereto as
Exhibit A) are incorporated into this Agreement solely for reference and convenience purposes and shall have no effectiveness unless and until such documents are executed and delivered by the
appropriate parties (at which point, such executed documents shall constitute agreements separate and distinct from this Agreement). 

        (b)   Except
as otherwise provided in Section 11.14(c), in the event of any conflict or inconsistency between the terms set forth in the body of this Agreement and the
terms of any Exhibit attached hereto (other than Exhibit G), the terms of the body of this Agreement shall govern and take precedence; provided, however, with respect to any WTG that is subject
to the Modified Obligations, in the event of any conflict or inconsistency between the terms set forth in the body of this document and the terms of Exhibit G, the terms of Exhibit G
shall govern and take precedence. 

        (c)   Notwithstanding
anything to the contrary contained herein, the term "Agreement" shall, solely with respect to any WTG that is subject to the Modified Obligations, mean
the body of this document and all Exhibits attached hereto (including, without limitation, Exhibit G). In all other cases, the term "Agreement" shall mean the body of this document and all
Exhibits attached hereto (other than Exhibit G). 

        (d)   To
the maximum extent possible, the terms of this Agreement and the terms of the Performance Side Letter shall be interpreted to be consistent with each other, and if
necessary interpreted together to determine the outcome of a matter affected by both this Agreement and the Performance Side Letter; provided, however, notwithstanding anything to the contrary
contained in this Agreement, in the event of any conflict or inconsistency between the terms of this Agreement and the terms of the Performance Side Letter as to the subject matter reflected in the
Performance Side Letter, the terms and provisions of the Performance Side Letter shall govern and control. 

        11.15    Force
Majeure.    (a)    If an event of Force Majeure or Owner Default occurs that adversely affects
Suzlon's performance under the Agreement (including, without limitation, 

65

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

Suzlon's
cost of performing its obligations under the Agreement), Suzlon shall be entitled to an equitable adjustment in the Contract Price, the fees payable pursuant to this Agreement and/or the
schedules for the performance of the Work (including, without limitation, the Deadline Dates) reflecting the impact of such event of Force Majeure or Owner Default, which adjustment shall be reflected
in an amendment to this Agreement. Notwithstanding the foregoing, if Owner and Suzlon reasonably believe that the then current schedules for Suzlon's performance of the Work may be preserved, then
Owner shall have the option of so increasing the Contract Price (and/or implementing such other mutually acceptable measures at the Owner's sole cost) to preserve the then current schedules for
Suzlon's performance of the Work. If Suzlon requests such amendment as a result of an event of Force Majeure, Suzlon must do so in writing within fifteen (15) Business Days after Suzlon first
becomes aware of such event. 

        (b)   If
an event of Force Majeure or Suzlon Default occurs that adversely affects Owner's ability to meet any Mechanical Completion Deadline or its Expected MC Date, Owner
shall be entitled to an equitable adjustment in such Mechanical Completion Deadline or such Expected MC Date reflecting the impact of such event of Force Majeure or Suzlon Default, which adjustment
shall be reflected in an amendment to this Agreement, provided (x) if Owner requests an amendment as to such Mechanical Completion Deadline as a result of an event of Force Majeure, Owner must
do so in writing within fifteen (15) Business Days after Owner first becomes aware of such event, and (y) if Owner requests an amendment as to such Expected MC Date, Owner must comply
with the terms and provisions of Section 2.2(c)(ii). 

66

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

 

        IN WITNESS WHEREOF, the Parties have caused this Agreement to be executed by their duly authorized representatives as of the date and year
first above written. 

	 	 	EDISON MISSION ENERGY
	

 	
 	

By:	
 	

/s/ Gerard P. Loughman

	 	 	 	 	Name: Gerard P. Loughman
	

 	
 	

SUZLON WIND ENERGY CORPORATION
	

 	
 	

By:	
 	

/s/ Andris Cukurs

	 	 	 	 	Name: Andris Cukurs
	 	 	 	 	Title: Chief Executive Officer

67

[***]
Confidential portions of this document have been redacted and filed separately with the Commission.

QuickLinks

PURCHASE & RESERVATION AGREEMENT

ARTICLE 3 CONTRACT PRICE; PAYMENTS TO SUZLONExhibit 10.1  

EXECUTION
VERSION 

	

	
THIRD AMENDED AND RESTATED CREDIT AGREEMENT
	
 dated as of June 29, 2007
	
 among
	
 MIDWEST GENERATION, LLC
	
 and
	
 THE LENDERS REFERRED TO HEREIN
	
 and
	
 JPMORGAN CHASE BANK, N.A.,

as Administrative Agent for the Lenders
	
 and
	
 THE ISSUING LENDERS REFERRED TO HEREIN
	
 J.P. MORGAN SECURITIES INC. and

CITIGROUP GLOBAL MARKETS INC.,

as Joint Lead Arrangers
	
 J.P. MORGAN SECURITIES INC. and

CITIGROUP GLOBAL MARKETS INC.,

as Joint Bookrunners
	
 UNION BANK OF CALIFORNIA, N.A.,

as Syndication Agent
	
 CITIGROUP GLOBAL MARKETS INC.,

CREDIT SUISSE and

GOLDMAN SACHS CREDIT PARTNERS L.P.,

as Co-Documentation Agents
	

   
TABLE OF CONTENTS 

	 
	 
	 	Page

	 ARTICLE I    DEFINITIONS AND ACCOUNTING TERMS	 	1
	 	SECTION 1.1	Defined Terms	 	1
	 	SECTION 1.2	Use of Defined Terms	 	29
	 	SECTION 1.3	Cross-References	 	29
	 	SECTION 1.4	Accounting and Financial Determinations	 	29
	
  ARTICLE II    COMMITMENTS AND BORROWING PROCEDURES	
 	

30
	 	SECTION 2.1	Loans	 	30
	 	SECTION 2.2	Loans	 	30
	 	 	SECTION 2.2.1	Obligations of Lenders	 	30
	 	 	SECTION 2.2.2	Type of Loans	 	30
	 	 	SECTION 2.2.3	Minimum Amounts; Limitation on Number of Loans	 	30
	 	 	SECTION 2.2.4	Limitations on Interest Periods	 	30
	 	SECTION 2.3	Borrowing Procedure	 	30
	 	SECTION 2.4	Continuation and Conversion Elections	 	31
	 	SECTION 2.5	Funding	 	31
	 	SECTION 2.6	Letters of Credit	 	31
	 	 	SECTION 2.6.1	Notice of Issuance, Amendment, Renewal or Extension	 	32
	 	 	SECTION 2.6.2	Limitations on Amounts	 	32
	 	 	SECTION 2.6.3	Expiration Date	 	32
	 	 	SECTION 2.6.4	Participations	 	32
	 	 	SECTION 2.6.5	Reimbursement	 	33
	 	 	SECTION 2.6.6	Obligations Absolute	 	33
	 	 	SECTION 2.6.7	Disbursement Procedures	 	34
	 	 	SECTION 2.6.8	Interim Interest	 	35
	 	 	SECTION 2.6.9	Addition and Replacement of Issuing Lenders	 	35
	 	 	SECTION 2.6.10	Cash Collateralization	 	35
	 	 	SECTION 2.6.11	Existing Letters of Credit	 	36
	
  ARTICLE III    REPAYMENTS, PREPAYMENTS, INTEREST AND FEES	
 	

36
	 	SECTION 3.1	Repayments, Amortization and Prepayments	 	36
	 	 	SECTION 3.1.1	Optional Prepayments and Commitment Reductions	 	36
	 	 	SECTION 3.1.2	Acceleration; Penalty	 	37
	 	SECTION 3.2	Interest Provisions	 	37
	 	 	SECTION 3.2.1	Rates	 	37
	 	 	SECTION 3.2.2	Default Rates	 	37
	 	 	SECTION 3.2.3	Payment Dates	 	37
	 	 	SECTION 3.2.4	Interest Rate Determination	 	38
	 	SECTION 3.3	Fees	 	38
	 	 	SECTION 3.3.1	Commitment Fee	 	38
	 	 	SECTION 3.3.2	Letter of Credit Fees	 	38
	 	 	SECTION 3.3.3	Other Fees	 	39
	 	 	SECTION 3.3.4	Payment of Fees	 	39
	 	SECTION 3.4	Extension of Commitment Termination Date	 	39
	
  ARTICLE IV    CERTAIN LIBO RATE AND OTHER PROVISIONS	
 	

40
	 	SECTION 4.1	LIBO Rate Lending Unlawful	 	40
	 	SECTION 4.2	Inability to Determine Rates	 	40
	 	SECTION 4.3	Increased LIBO Rate Loan Costs	 	40
	 	 	 	 

i

 

	 	SECTION 4.4	Obligation to Mitigate	 	40
	 	SECTION 4.5	Funding Losses	 	41
	 	SECTION 4.6	Increased Capital Costs	 	42
	 	SECTION 4.7	Taxes	 	42
	 	SECTION 4.8	Payments, Computations	 	43
	 	SECTION 4.9	Sharing of Payments	 	43
	 	SECTION 4.10	Setoff	 	44
	 	SECTION 4.11	Replacement of Lender	 	44
	
  ARTICLE V    CONDITIONS TO LOANS	
 	

45
	 	SECTION 5.1	Conditions to Effectiveness	 	45
	 	 	SECTION 5.1.1	Delivery of Loan Documents	 	45
	 	 	SECTION 5.1.2	Officer's Certificates	 	45
	 	 	SECTION 5.1.3	Resolutions	 	46
	 	 	SECTION 5.1.4	Opinions of Counsel	 	46
	 	 	SECTION 5.1.5	Closing Fees, Expenses	 	46
	 	 	SECTION 5.1.6	Financial Statements	 	46
	 	 	SECTION 5.1.7	Existing Indebtedness	 	46
	 	 	SECTION 5.1.8	Lien Search; Recordings and Filings	 	47
	 	 	SECTION 5.1.9	Collateral Trust Agreement	 	47
	 	 	SECTION 5.1.10	Title Policies	 	47
	 	 	SECTION 5.1.11	Projections and Rating Agency Presentations	 	47
	 	 	SECTION 5.1.12	Approvals	 	48
	 	 	SECTION 5.1.13	Ratings	 	48
	 	 	SECTION 5.1.14	Energy Management Agreements	 	48
	 	 	SECTION 5.1.15	Insurance	 	48
	 	SECTION 5.2	Credit Extensions	 	48
	 	 	SECTION 5.2.1	Representations and Warranties; No Default	 	48
	 	 	SECTION 5.2.2	Borrowing or Letter of Credit Request	 	49
	 	SECTION 5.3	Satisfactory Legal Form	 	49
	
  ARTICLE VI    REPRESENTATIONS AND WARRANTIES	
 	

49
	 	SECTION 6.1	Financial Information	 	49
	 	SECTION 6.2	Organization; Power	 	49
	 	SECTION 6.3	Due Authorization; Non-Contravention	 	49
	 	SECTION 6.4	Approvals	 	50
	 	SECTION 6.5	Accuracy of Information	 	50
	 	SECTION 6.6	Validity	 	50
	 	SECTION 6.7	Compliance with Law and Contractual Obligations	 	50
	 	SECTION 6.8	Regulations T, U and X	 	50
	 	SECTION 6.9	Litigation	 	51
	 	SECTION 6.10	Ownership of Properties	 	51
	 	SECTION 6.11	Taxes	 	51
	 	SECTION 6.12	Investment Company Act; Public Utility Holding Company Act; Other Regulations	 	51
	 	SECTION 6.13	Environmental Warranties	 	52
	 	SECTION 6.14	The Obligations	 	52
	 	SECTION 6.15	Pension and Welfare Plans	 	52
	 	SECTION 6.16	Solvency	 	53
	 	 	 	 

ii

 

	
  ARTICLE VII    COVENANTS	
 	

53
	 	SECTION 7.1	Affirmative Covenants	 	53
	 	 	SECTION 7.1.1	Financial Information, Reports, Notices	 	53
	 	 	SECTION 7.1.2	Continuation of Business and Maintenance of Existence	 	54
	 	 	SECTION 7.1.3	Compliance with Requirements of Law and Contractual Obligations	 	55
	 	 	SECTION 7.1.4	Maintenance of Facilities	 	55
	 	 	SECTION 7.1.5	Insurance	 	55
	 	 	SECTION 7.1.6	Books and Records	 	56
	 	 	SECTION 7.1.7	Environmental Covenant	 	56
	 	 	SECTION 7.1.8	Further Assurances	 	56
	 	 	SECTION 7.1.9	Financial Covenant	 	57
	 	 	SECTION 7.1.10	Use of Proceeds	 	57
	 	 	SECTION 7.1.11	Separateness	 	57
	 	SECTION 7.2	Negative Covenants	 	58
	 	 	SECTION 7.2.1	Restrictions on Secured Indebtedness.	 	58
	 	 	SECTION 7.2.2	Liens	 	58
	 	 	SECTION 7.2.3	Consolidation, Merger	 	59
	 	 	SECTION 7.2.4	Asset Sales	 	60
	 	 	SECTION 7.2.5	Investments	 	60
	 	 	SECTION 7.2.6	Transactions with Affiliates	 	61
	 	 	SECTION 7.2.7	Restricted Payments	 	61
	 	 	SECTION 7.2.8	Restrictive Agreements	 	62
	 	 	SECTION 7.2.9	Limitation on Lines of Business	 	62
	 	 	SECTION 7.2.10	Swap Agreements	 	62
	 	 	SECTION 7.2.11	Amendment, Modification or Waiver of Certain Documents	 	62
	 	 	SECTION 7.2.12	Specified Transaction	 	63
	
  ARTICLE VIII    EVENTS OF DEFAULT	
 	

63
	 	SECTION 8.1	Listing of Events of Default	 	63
	 	 	SECTION 8.1.1	Non-Payment of Obligations	 	63
	 	 	SECTION 8.1.2	Breach of Warranty	 	63
	 	 	SECTION 8.1.3	Non-Performance of Certain Covenants and Obligations	 	63
	 	 	SECTION 8.1.4	Non-Performance of Other Covenants and Obligations	 	63
	 	 	SECTION 8.1.5	Default on other Indebtedness; Payment Default under EMMT Agreements	 	63
	 	 	SECTION 8.1.6	Bankruptcy, Insolvency	 	64
	 	 	SECTION 8.1.7	Pension Plans	 	65
	 	 	SECTION 8.1.8	Judgments	 	65
	 	 	SECTION 8.1.9	Regulatory Violation	 	65
	 	 	SECTION 8.1.10	Loan Documentation	 	65
	 	 	SECTION 8.1.11	Change-In-Control	 	65
	 	 	SECTION 8.1.12	Powerton/Joliet Leases	 	65
	 	 	SECTION 8.1.13	EME Obligations	 	65
	 	 	SECTION 8.1.14	Powerton/Joliet Documentation	 	65
	 	 	SECTION 8.1.15	EME Default	 	66
	 	SECTION 8.2	Action if Bankruptcy	 	66
	 	SECTION 8.3	Action if Other Event of Default	 	66
	 	SECTION 8.4	Rescission of Declaration	 	66
	 	 	 	 

iii

 

	
  ARTICLE IX    THE ADMINISTRATIVE AGENT	
 	

66
	 	SECTION 9.1	Actions	 	66
	 	SECTION 9.2	Funding Reliance	 	67
	 	SECTION 9.3	Exculpation	 	67
	 	SECTION 9.4	Successor	 	68
	 	SECTION 9.5	Loans by JPMCB	 	68
	 	SECTION 9.6	Reliance by Administrative Agent	 	68
	 	SECTION 9.7	Notice of Default	 	69
	 	SECTION 9.8	Credit Decisions	 	69
	 	SECTION 9.9	Copies	 	69
	 	SECTION 9.10	Collateral	 	69
	
  ARTICLE X    MISCELLANEOUS PROVISIONS	
 	

70
	 	SECTION 10.1	Waivers, Amendments	 	70
	 	SECTION 10.2	Notices	 	71
	 	SECTION 10.3	Payment of Costs and Expenses	 	71
	 	SECTION 10.4	Indemnification	 	72
	 	SECTION 10.5	Survival	 	73
	 	SECTION 10.6	Severability	 	73
	 	SECTION 10.7	Headings	 	73
	 	SECTION 10.8	Execution in Counterparts	 	73
	 	SECTION 10.9	Governing Law; Entire Agreement	 	73
	 	SECTION 10.10	Successors and Assigns	 	73
	 	SECTION 10.11	Sale and Transfer of Loans; Participations in Loans	 	74
	 	 	SECTION 10.11.1	Assignments	 	74
	 	 	SECTION 10.11.2	Participations	 	75
	 	SECTION 10.12	Other Transactions	 	76
	 	SECTION 10.13	Submission To Jurisdiction; Waivers	 	77
	 	SECTION 10.14	WAIVERS OF JURY TRIAL	 	77
	 	SECTION 10.15	Non-Recourse Persons	 	77
	 	SECTION 10.16	Acknowledgments	 	77
	 	SECTION 10.17	Confidentiality	 	78
	 	SECTION 10.18	USA PATRIOT Act	 	78
	 	SECTION 10.19	EMMH Credit Agreement	 	78
	 	SECTION 10.20	Retiring Lenders	 	78

	
 	

 	

 	
 	

 
	 SCHEDULES	 	 
	1.1(a)	–	Addresses for Notices and Lending Offices	 	 
	1.1(b)	–	Commitments	 	 
	2.2	–	Closing Date Bank Accounts	 	 
	2.6.11	–	Letters of Credit	 	 
	3.2.1	–	Pricing Grid	 	 
	7.2.1(a)	–	Capitalized Lease Liabilities and Operating Lease Liabilities	 	 
	 	 	 	 	 

iv

 

	
  EXHIBITS	
 	

 
	A	–	Form of Borrowing Request	 	 
	B	–	Form of Continuation/Conversion Notice	 	 
	C	–	Form of Assignment Agreement	 	 
	 D–1	–	Form of Opinion of Special New York Counsel to the Borrower and the Midwest Related Parties	 	 
	 D–2	–	Form of Opinion of Special New York Counsel to the Borrower and the Midwest Related Parties Regarding UCC Matters	 	 
	 D–3	–	Form of Opinion of Internal Counsel to the Borrower and the Midwest Related Parties	 	 
	 D–4	–	Form of Opinion of Internal Counsel to EMMT	 	 
	 D–5	–	Form of Opinion of Illinois Regulatory Counsel to the Borrower	 	 
	 D–6	–	Form of Opinion of Federal Regulatory Counsel to the Borrower	 	 
	E	–	Form of Communications Agreement	 	 
	F	–	Form of Subsidiary Guarantee	 	 

v

   
        THIRD AMENDED AND RESTATED CREDIT AGREEMENT dated as of June 29, 2007 among MIDWEST GENERATION, LLC, a limited liability company duly organized and validly existing under
the laws of Delaware (the "Borrower"), the Continuing Lenders (as defined below), the New Lenders (as defined below), the
other Lenders from time to time party hereto, the Issuing Lenders party hereto, JPMORGAN CHASE BANK, N.A. ("JPMCB"), as Administrative Agent for the
Lenders and the Issuing Lenders party hereto. 

RECITALS

        A.    The
Borrower is party to that certain Second Amended and Restated Credit Agreement dated as of December 15, 2005 (as amended, supplemented, amended and
restated or otherwise modified and in effect immediately prior to the satisfaction (or waiver) of the conditions set forth in Section 5,
the "Existing Credit Agreement") among the Borrower, the lenders party thereto (the "Existing
Lenders"), the issuing lenders party thereto and Citicorp North America, Inc., as Administrative Agent. 

        B.    Each
of the Existing Lenders not a party hereto or not party to an Accession Agreement (each, a "Retiring Lender") will
cease to be a "Lender" under the Existing Credit Agreement as of the Closing Date. Each (a) Existing Lender party hereto or party to an Accession Agreement (each, a
"Continuing Lender") and each (b) Person party hereto (other than Continuing Lenders) (each, a
"New Lender") shall become or continue as a "Lender" under the Existing Credit Agreement as amended and restated by this Agreement. 

        C.    The
Borrower has requested certain amendments to the provisions of the Existing Credit Agreement, including the extension of the "Revolver Commitments" and the "Revolver
Loans" under (and as defined in) the Existing Credit Agreement, and therefore has requested that the Continuing Lenders and New Lenders provide the credit facilities described herein
under this Agreement which shall amend and restate the Existing Credit Agreement. 

        D.    The
Continuing Lenders and the New Lenders are willing to amend and restate the Existing Credit Agreement upon and subject to the terms and conditions hereinafter
set forth. 

        NOW,
THEREFORE, the parties hereto agree as follows: 

ARTICLE
I 

DEFINITIONS
AND ACCOUNTING TERMS 

        SECTION 1.1    Defined Terms.    The following terms (whether or not underscored) when used in this Agreement,
including its preamble and recitals, shall, except where the context otherwise requires, have the following meanings (such meanings to be equally applicable to the singular and plural
forms thereof): 

        "Additional Commitment Lender" has the meaning set forth in Section 3.4(b). 

        "Adjusted LIBO Rate" means, with respect to any LIBO Rate Loan for any Interest Period, an interest rate per annum (rounded upwards, if
necessary, to the next 1/16 of 1%) equal to (a) the LIBO Rate for such Interest Period multiplied by (b) the Statutory Reserve Rate. 

        "Administrative Agent" means JPMCB in its capacity as administrative agent for the Lenders and Issuing Lenders hereunder, and includes
each other Person as may have subsequently been appointed as the successor Administrative Agent pursuant to Section 9.4. 

        "Administrative Questionnaire" means an Administrative Questionnaire in form and substance satisfactory to the Administrative Agent. 

Third Amended and Restated Credit Agreement

1

 

        "Affiliate" of any Person means any other Person directly or indirectly controlling or controlled by or under direct or indirect common
control with such Person. For purposes of this definition, "control," as used with respect to any Person, means the possession, directly or indirectly, of the power to direct or cause the direction of
the management or policies of such Person, whether through the ownership of voting securities, by agreement or otherwise; provided, that Beneficial
Ownership of 10% or more of
the Voting Stock of a Person will be deemed to be control. For purposes of this definition, the terms "controlling," "controlled by" and "under common control with" have correlative meanings. 

        "Affiliated Indebtedness" means Indebtedness of the Borrower or any of its Subsidiaries that is owed to the Borrower or any of
its Affiliates. 

        "Agent-Related Persons" means JPMCB and each other Person as may have subsequently been appointed as the successor Administrative Agent
pursuant to Section 9.4, together with their respective Affiliates, and the officers, directors, employees, agents and
attorneys-in-fact of JPMCB, each such other Person and such Affiliates. 

        "Agreement" means, on any date, this Third Amended and Restated Credit Agreement as originally in effect on the Closing Date and as
thereafter from time to time amended, supplemented, amended and restated or otherwise modified and in effect on such date. 

        "Alternate Base Rate" means, for any day, a rate per annum equal to the greater of (a) the Prime Rate in effect on such day and
(b) the Federal Funds Effective Rate in effect on such day plus 1/2 of 1%. Any change in the Alternate Base Rate due to a change
in the Prime Rate or the Federal Funds Effective Rate shall be effective from and including the effective date of such change in the Prime Rate or the Federal Funds Effective Rate, respectively. 

        "Applicable Margin" means, for any day with respect to any LIBO Rate Loans or Base Rate Loans, the rate per annum in effect for such type
of Loans for such day based on the Borrower's Debt Rating for such day determined as provided in the Pricing Grid. 

        "Approved Funds" means, with respect to any Lender that is a fund that invests in commercial loans, any other fund that invests in
commercial loans and is managed or advised by the same investment advisor as such Lender or by an Affiliate of such investment advisor. 

        "Asset Sale" has the meaning set forth in Section 7.2.4. 

        "Assignee" has the meaning set forth in Section 10.11.1. 

        "Assignment Agreement" means an Assignment Agreement substantially in the form of  Exhibit C. 

        "Assignor" has the meaning set forth in Section 10.11.1. 

        "Authorized Representative" means, relative to any Person, those of its officers and employees whose signatures and incumbency shall have
been certified to the Administrative Agent and the Lenders pursuant to Section 5.1.3. 

        "Availability Period" means the period from and including the Closing Date to but excluding the earlier of the Commitment Termination Date
and the date of termination of the Commitments. 

        "Back-to-Back Transaction" has the meaning set forth in the Energy Management Agreements. 

        "Bank Account" means the Closing Date Bank Accounts and all other deposit accounts (as such term is defined in the UCC) now or
hereafter owned by the Borrower. 

Third Amended and Restated Credit Agreement

2

 

        "Base Rate Loan" means a Loan bearing interest at a fluctuating rate of interest per annum determined by reference to the Alternate Base
Rate plus the Applicable Margin for Base Rate Loans from time to time in effect. 

        "Beneficial Owner" has the meaning assigned to such term in Rule 13d-3 and Rule 13d-5 under
the Exchange Act, except that in calculating the beneficial ownership of any particular "person" (as that term is used in Section 13(d)(3) of the Exchange Act), such "person" will be
deemed to have beneficial ownership of all securities that such "person" has the right to acquire by conversion or exercise of other securities, whether such right is currently exercisable or is
exercisable only after the passage of time. The terms "Beneficially Owns", "Beneficially Owned" and "Beneficial Ownership" have a corresponding meaning. 

        "Board" means the Board of Governors of the Federal Reserve System of the United States or any successor thereto. 

        "Board of Directors" means (a) with respect to a corporation, the board of directors of the corporation, (b) with respect to
a partnership, the general partners or the management committee of the partnership,
(c) with respect to a limited liability company, the board of managers of the limited liability company or (d) with respect to any other Person, the board or committee of such Person
serving a similar function. 

        "Borrower" has the meaning set forth in the preamble. 

        "Borrower Debt" means, on any date, the sum (without duplication) of the following indebtedness of the Borrower: (a) all
indebtedness for borrowed money other than Subordinated Indebtedness; (b) any Capitalized Lease Liabilities; (c) all reimbursement obligations with respect to surety bonds, letters of
credit (to the extent not collateralized with cash or Cash Equivalent Investments), bankers' acceptances and similar instruments (in each case, whether or not matured); and
(d) all obligations evidenced by notes, bonds, debentures or similar instruments, including obligations so evidenced incurred in connection with the acquisition of property, assets
or businesses. 

        "Borrower Security Agreement" means the Security Agreement dated as of April 27, 2004 between the Borrower and the Collateral
Trustee, as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Borrowing" means Loans of the same type and, in the case of LIBO Rate Loans, having the same Interest Period, made by all Lenders on the
same Business Day pursuant to the same Borrowing Request in accordance with Section 2.3. 

        "Borrowing Request" means each loan request and certificate duly executed by an Authorized Representative of the Borrower, substantially
in the form of Exhibit A. 

        "Business Day" means: 

        (a)   any
day which is neither a Saturday or Sunday nor a legal holiday on which the Lenders are authorized or required to be closed in New York,
New York; and 

        (b)   relative
to the making, continuing, prepaying or repaying of any LIBO Rate Loans, any day on which dealings in Dollars are carried on in the London interbank market. 

        "Capacity" means, with respect to any Facility, the total electric generating capacity of such Facility measured in megawatts. 

        "Capital Lease" means, with respect to any Person, a lease of (or other Indebtedness arrangements conveying the right to use) real
or personal property of such Person which is required to be classified 

Third Amended and Restated Credit Agreement

3

 

and
accounted for as a capital lease or a liability set forth on the balance sheet of such Person or such Person's Subsidiaries in accordance with GAAP. 

        "Capital Stock" means: 

        (a)   in
the case of a corporation, corporate stock; 

        (b)   in
the case of an association or business entity, any and all shares, interests, participations, rights or other equivalents (however designated) of corporate stock; 

        (c)   in
the case of a partnership or limited liability company, partnership interests (whether general or limited) or membership interests; and 

        (d)   any
other interest or participation that confers on a Person the right to receive a share of the profits and losses of, or distributions of assets of, the
issuing Person, 

but
excluding from all of the foregoing any debt securities convertible into Capital Stock, whether or not such debt securities include any right of participation with Capital Stock. 

        "Capitalized Lease Liabilities" of any Person means all monetary obligations of such Person under any leasing or similar arrangement
which, in accordance with GAAP, would be classified as Capital Leases, and, for purposes of each Loan Document, the amount of such obligations shall be the capitalized amount thereof, determined in
accordance with GAAP (including, to the extent excluded, with respect to the Borrower, the Powerton/Joliet Lease Liabilities). 

        "Cash Collateralize" means to pledge and deposit with or deliver to the Administrative Agent in accordance with  Section 2.6.10, for the ratable benefit of the
Administrative Agent, the Issuing Lenders and the Lenders, as collateral for the
LC Exposure, cash or deposit account balances pursuant to documentation in form and substance satisfactory to the Administrative Agent and the Issuing Lenders. 

        "Cash Equivalent Investment" means, at any time: 

        (a)   any
evidence of Indebtedness, maturing not more than one year after such time, issued or guaranteed by the United States government or an agency
thereof; or 

        (b)   investments
in securities or bank instruments rated at least "A" by S&P or "A2" by Moody's or "A-1" by S&P or "P-1" by Moody's and with
maturities of not more than one year; or 

        (c)   money
market funds that (i) comply with the criteria set forth in Securities and Exchange Commission Rule 2a-7 under the Investment
Company Act of 1940, as amended and (ii) have portfolio assets of at least $1,000,000,000. 

        "CERCLIS" means the Comprehensive Environmental Response Compensation Liability Information System List. 

        "Change-In-Control" means the occurrence of any of the following: 

        (a)   the
adoption of a plan relating to the liquidation or dissolution of the Borrower; 

        (b)   the
first day on which EME (or the then-current Successor (as defined below)) fails to own, directly or indirectly, a majority of the Equity
Interests of the Borrower; provided that it shall not be deemed to be a Change-In-Control described in this clause (b) if, on the date of the transaction or last of a
series of transactions resulting in such failure to own (the "Subject Transaction") after giving effect to the Subject Transaction: 

        (i)    one
Person (each, a "Successor") owns, directly or indirectly, a majority of the Equity Interests in the Borrower; 

Third Amended and Restated Credit Agreement

4

 

        (ii)   the
Successor is, directly or indirectly, publicly-owned and has, directly or indirectly, a market capitalization of at least $1,000,000,000 (pro forma after
giving effect to the Subject Transaction); 

        (iii)  the
Successor is (or shall become) the guarantor under the Powerton Guarantees and the Joliet Guarantees; 

        (iv)  the
Successor (pro forma after giving effect to the Subject Transaction) has Debt Ratings that are the same or better than the then-current Debt
Ratings of EME (or the then-current Successor) from S&P and Moody's; and 

        (v)   the
Borrower has Debt Ratings that are the same or better than the Debt Ratings before giving effect to the Subject Transaction (or the announcement thereof)
(or if such Debt Ratings are not the same or better than the Debt Ratings before giving effect to the Subject Transaction (or announcement thereof), the acts, events or circumstances
cited by the Rating Agencies for their action shall not have included the Subject Transaction (or the announcement thereof)); provided that it shall not be deemed to be a
Change-In-Control in the event that three Rating Agencies are continuing to provide Debt Ratings of the Borrower and the Debt Ratings from two such Rating Agencies are the same
or better than the Debt Ratings before giving effect to the Subject Transaction (or the announcement thereof); or 

        (c)   the
first day on which EMMH fails to own, directly or indirectly, 100% of the Equity Interests of the Borrower; provided,
that EMMH may be consolidated, transferred or merged with or into MGE or the Borrower; provided,  further, that MGE reaffirms the pledge of the Equity
Interests of the Borrower for the benefit of the Collateral Trustee. 

        "Closing Date" means the date that this Agreement becomes effective pursuant to  Section 5.1. 

        "Closing Date Bank Accounts" means each of the deposit accounts (as such term is defined in the UCC) of the Borrower listed on  Schedule 2.2. 

        "CNAI" means Citicorp North America, Inc. 

        "Code" means the Internal Revenue Code of 1986, as amended. 

        "Collateral" means any assets of the Borrower, its Subsidiaries, EMMT and the Midwest Related Parties, whether now owned or hereafter
acquired, upon which a Lien is purported to be created by any Security Document. 

        "Collateral Trust Agreement" means the First Amended and Restated Collateral Trust Agreement dated as of June 29, 2007 by and among
the Borrower, the Obligors from time to time party thereto, the Administrative Agent and the Collateral Trustee, as amended, supplemented, amended and restated or otherwise modified and in effect from
time to time. 

        "Collateral Trust Joinder" has the meaning set forth in the Collateral Trust Agreement. 

        "Collateral Trustee" has the meaning set forth in the Collateral Trust Agreement. 

        "Commitment" means, with respect to each Lender, the commitment, if any, of such Lender to make Loans and to acquire participations in
Letters of Credit hereunder, expressed as an amount representing the maximum aggregate amount of such Lender's Exposure hereunder, as such commitment may be (a) reduced from time to time
pursuant to Section 3.1 and (b) reduced or increased from time to time pursuant to assignments by or to such Lender pursuant to  Section 10.11.1. The initial amount of each Lender's Commitment is set forth on  Schedule 1.1(b) or in the Assignment 

Third Amended and Restated Credit Agreement

5

 

Agreement
pursuant to which such Lender shall have assumed its Commitment, as applicable. The initial aggregate amount of the Lenders' Commitments is $500,000,000. 

        "Commitment Termination Date" means June 29, 2012, as estimated from time to time in accordance with  Section 3.4. 

        "Commodity Hedge and Power Sales Agreement" means any agreement (including each confirmation entered into pursuant to a master agreement
or similar agreement) providing for any swap, cap, collar, put, call, floor, future, option, spot, forward, credit sleeve, power and/or capacity purchase and sale agreement (including, but not limited
to, option and heat rate options), fuel purchase and sale agreement, emissions credit purchase and sale agreement, power transmission agreement, fuel transportation agreement, fuel storage agreement,
weather derivatives, netting agreement or similar agreement entered into in respect of any commodity, any energy management agreement, and any agreement providing for credit support for any of the
foregoing, in each case not for speculative purposes. 

        "Communications Agreement" means the Communications Agreement dated as of June 29, 2007 between the Borrower and the Administrative
Agent, substantially in the form of Exhibit E, as amended, supplemented, amended and restated or otherwise modified and in effect from time
to time. 

        "Consolidated Net Tangible Assets" means as of any date of determination, the total amount of all of the Company's assets, determined on a
consolidated basis in accordance with GAAP as of such date, less the sum of (a) the Company's consolidated current liabilities determined in accordance with GAAP and (b) the Company's
assets properly classified as intangible assets in accordance with GAAP, except for any intangible assets that are distribution or related contracts with an assignable value. 

        "Consolidated Net Worth" means, at any date, the consolidated members' equity of the Borrower determined as of such date without giving
effect to (a) any non-cash charges relating to cumulative changes in accounting or the effect on members' equity from the restatement of prior periods resulting from the adoption of
new accounting standards or interpretations after the Closing Date and (b) accumulated other comprehensive gain or loss plus, to the extent not otherwise included therein, the liquidation
preference at such date of non-redeemable preferred equity of the Borrower. 

        "Contingent Liability" means any agreement, undertaking or arrangement by which any Person Guarantees, endorses or otherwise becomes or is
contingently liable upon (by direct or indirect agreement, contingent or otherwise, to provide funds for payment, to supply funds to, or otherwise to invest in, a debtor, or otherwise to assure
a creditor against loss) the indebtedness, obligation or any other liability of any other Person (other than by endorsements of instruments in the course of collection), or Guarantees the payment of
dividends or other distributions upon the shares of any other Person. The amount of any Person's obligation under any Contingent Liability shall (subject to any limitation set forth therein) be deemed
for purposes of this Agreement to be the outstanding principal amount of the debt, obligation or other liability Guaranteed thereby; provided,  however,
that if the maximum amount of the debt, obligation or other liability Guaranteed thereby has not been established, the amount of such
Contingent Liability shall be the maximum reasonably anticipated amount of the debt, obligation or other liability; provided,  further, however, that any agreement to limit the maximum amount of such Person's obligation under such
Contingent Liability shall not, of and by itself, be deemed to establish the maximum reasonably anticipated amount of such debt, obligation or other liability. 

        "Continuation/Conversion Notice" means a notice of continuation or conversion and certificate duly executed by an Authorized
Representative of the Borrower, substantially in the form of Exhibit B. 

        "Continuing Lenders" has the meaning set forth in the recitals. 

Third Amended and Restated Credit Agreement

6

 

        "Contractual Obligation" means, as to any Person, any provision of any security issued by such Person or of any agreement, instrument or
other undertaking to which such Person is a party or by which it or any of its property is bound. 

        "Controlled Group" means all members of a controlled group of corporations and all members of a controlled group of trades or businesses
(whether or not incorporated) under common control which, together with the Borrower, are treated as a single employer under Section 414(b) or 414(c) of the Code or Section 4001
of ERISA. 

        "Core Facilities" means the Crawford Facility (other than the Crawford Peaking Unit), the Fisk Facility (other than the Fisk Peaking
Unit), the Waukegan Facility (other than Waukegan Unit 6 and the Waukegan Peaking Unit), the Joliet #9 Facility (other than the Joliet Peaking Unit), the Joliet Leased Facility, the Powerton
Leased Facility and the Will County Facility (other than Will County Units 1 and 2). 

        "Crawford Facility" means the Crawford station, 542 MW net coal-fired electric generating facility and related assets
owned by the Borrower, including the Crawford Peaking Unit, and located in Cook County, Illinois. 

        "Crawford Peaking Unit" means the 121 MW (nominal summer rating) gas—and oil-fired Crawford peaking unit
owned by the Borrower and located in Cook County, Illinois. 

        "Credit Extension" means and includes (a) any Borrowing and (b) any Issuance of, or participation in, any Letter
of Credit. 

        "Debt Rating" means, with respect to any Person, a rating by a Rating Agency of such Person's long-term debt which is not
secured or supported by a guarantee, letter of credit or other form of credit enhancement; provided that, with respect to the Borrower, "Debt Rating"
means, except for the purposes of Section 9.10(c) or unless otherwise specified, a rating by a Rating Agency of the Indebtedness evidenced by this Agreement. If such Rating Agency shall
have changed its system of classifications after the date hereof, a Debt Rating shall be considered to be at or above a specified level if it is at or above the new rating which most closely
corresponds to the specified level under the old rating system. 

        "Debt to Capitalization Ratio" means, on any date, the ratio of (a) Borrower Debt on such date to (b) the sum of
(i) Consolidated Net Worth on such date plus (ii) Borrower Debt on such date. 

        "Default" means any Event of Default or any condition, occurrence or event which, after notice or lapse of time or both, would constitute
an Event of Default. 

        "Derivatives Obligations" of any Person means all obligations of such Person in respect of any Eligible Commodity Hedge and Power Sale
Agreement secured by a Lien upon the property of the Borrower pursuant to Section 7.2.2(m) or Section 7.2.2(n). 

        "Dollar" and the sign "$" mean lawful money of the United States. 

        "Domestic Office" means, relative to any Lender, the office of such Lender designated on  Schedule 1.1(a) or designated in the Administrative Questionnaire of
such Lender or Assignment Agreement pursuant to which such Lender
became a Lender hereunder or such other office of a Lender (or any successor or assign of such Lender) within the United States as may be designated from time to time by notice from such
Lender, as the case may be, to each other Person party hereto. A Lender may have separate Domestic Offices for purposes of making, maintaining or continuing, as the case may be, Base
Rate Loans. 

Third Amended and Restated Credit Agreement

7

 

        "Eligible Commodity Hedge and Power Sale Agreement" means any Commodity Hedge and Power Sales Agreement which, at the time such Commodity
and Hedge and Power Sales Agreement is entered into, is structured such that the Permitted Hedge Counterparty's credit exposure and actual or projected mark-to-market exposure
to the Borrower is positively correlated with the price of the relevant commodity. 

        "EME" means Edison Mission Energy, a Delaware corporation. 

        "EME Trading Revolvers" means, collectively, (a) the Amended and Restated Revolving Credit Agreement (Margining) dated as of
April 27, 2004 between EMMT and EME, as amended, supplemented, amended and restated or otherwise modified and in effect from time to time, and (b) the Amended and Restated Revolving
Credit Agreement (Operations) dated as of April 27, 2004 between EMMT and EME, as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "EMMH" means Edison Mission Midwest Holdings Co., a Delaware corporation. 

        "EMMH Credit Agreement" means the Credit Agreement dated as of December 15, 1999 among EMMH, the Lenders party thereto and JPMorgan
Chase Bank (successor to The Chase Manhattan Bank), as administrative agent, as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "EMMH Pledge Agreement" means the Pledge Agreement dated as of April 27, 2004 between EMMH and the Collateral Trustee, as amended,
supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "EMMT" means Edison Mission Marketing & Trading, Inc., a California corporation. 

        "EMMT Indebtedness" means, without duplication: 

        (a)   all
indebtedness of EMMT for borrowed money; 

        (b)   all
obligations of EMMT issued, undertaken or assumed as the deferred purchase price of property or services which purchase price is due more than six months from the
date of incurrence of the obligation in respect thereof or is evidenced by a note or other instrument, except trade accounts arising in the ordinary course of business;  provided, that any such
obligation with respect to office equipment and similar property of EMMT entered into in the ordinary course of business shall
not be considered EMMT Indebtedness for purposes of this clause (b); 

        (c)   all
reimbursement obligations of EMMT with respect to surety bonds, letters of credit (to the extent not collateralized with cash or Cash Equivalent Investments),
bankers' acceptances and similar instruments (in each case, whether or not matured); 

        (d)   all
obligations of EMMT evidenced by notes, bonds, debentures or similar instruments, including obligations so evidenced incurred in connection with the acquisition of
property, assets or businesses; 

        (e)   all
indebtedness of EMMT created or arising under any conditional sale or other title retention agreement, or incurred as financing, in either case with respect to
property acquired by EMMT (even though the rights and remedies of the seller or bank under such agreement in the event of default are limited to repossession or sale of such property);  provided, that
any such conditional sale or other title retention agreement with respect to office equipment and similar property of EMMT entered into
in the ordinary course of business shall not be considered EMMT Indebtedness for purposes of this clause (e); 

Third Amended and Restated Credit Agreement

8

 

        (f)    all
Capitalized Lease Liabilities of EMMT and Operating Lease Liabilities of EMMT; 

        (g)   all
net obligations of EMMT with respect to EMMT (except insofar as incurred in connection with Swap Agreements permitted pursuant to  Section 7.2.10); 

        (h)   all
indebtedness referred to in clauses (a) through (g)
above secured by (or for which the holder of such indebtedness has an existing right, contingent or otherwise, to be secured by) any Lien upon or in property (including accounts and contracts
rights) owned by EMMT, even though EMMT has not assumed or become liable for the payment of such indebtedness; and 

        (i)    all
Contingent Liabilities of EMMT; provided, that NUG Contingent Liabilities shall not be EMMT Indebtedness for the
purposes of this clause (i); 

provided, that, EMMT Indebtedness shall not (x) include obligations and indebtedness of EMMT incurred in the ordinary course of business in
connection with Commodity Hedge and Power Sales Agreements permitted pursuant to Section 7.2.10 or (y) obligations of EMMT under each EME
Trading Revolver. 

        The
amount of any EMMT Indebtedness outstanding as of any date will be (i) the accreted value of such EMMT Indebtedness, in the case of any EMMT Indebtedness issued with original
issue discount, (ii) the principal amount of such EMMT Indebtedness, in the case of any other EMMT Indebtedness and (iii) in respect of Indebtedness of another Person secured by a Lien
on the assets of EMMT, the lesser of (A) the fair market value of such asset at the date of determination and (B) the amount of Indebtedness of such other Person. 

        "EMMT Security Agreement" means the Security Agreement dated as of April 27, 2004 between EMMT and the Collateral Trustee, as
amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Energy Management Agreements" means the Master Purchase Agreement, the Midwest Trading Revolver and each other agreement between EMMT and
the Borrower (as each such other agreement may be amended, supplemented, amended and restated or otherwise modified and in effect from time to time) relating to energy sales and fuel purchases
by the Borrower (including the posting of collateral for such sales and purchases). 

        "Environmental CapEx Debt" means Indebtedness of the Borrower incurred for the purpose of financing Environmental Capital Expenditures. 

        "Environmental Capital Expenditures" means capital expenditures deemed necessary by the Borrower to comply with Environmental Laws. 

        "Environmental Laws" means all applicable Federal, state or local statutes, laws, ordinances, codes, rules, regulations and guidelines
(including consent decrees and administrative orders) relating to Hazardous Materials and/or to public health and protection of the environment. 

        "Equity Interests" means Capital Stock and all warrants, options or other rights to acquire Capital Stock (but excluding any debt
security that is convertible into, or exchangeable for, Capital Stock). 

        "ERISA" means the Employee Retirement Income Security Act of 1974, as amended, and any successor statute of similar import, together with
the regulations thereunder, in each case as in effect from time to time. References to sections of ERISA also refer to any successor sections. 

        "Event of Default" has the meaning set forth in Section 8.1. 

        "Exchange Act" means the Securities Exchange Act of 1934, as amended. 

Third Amended and Restated Credit Agreement

9

   
        "Excluded Taxes" means, with respect to the Administrative Agent, the Issuing Lenders or any Lender or any other recipient of any payment
to be made by or on account of any obligation of the Borrower hereunder or under any other Loan Document, (a) income or franchise Taxes imposed on (or measured by) its net income by the
United States of America, or by the jurisdiction under the laws of which such recipient is organized or in which its principal office is located or, in the case of any Lender, in which its
applicable lending office is located, (b) any branch profits Taxes imposed by the United States of America or any similar Tax imposed by any other jurisdiction in which it is located
(other than a jurisdiction in which it is treated as being located solely by reason of its participation in transactions contemplated by the Loan Documents), (c) in the case of a
Non-U.S. Lender, any Tax that is imposed on amounts payable to such Non-U.S. Lender at the time such Non-U.S. Lender becomes a party to this
Agreement, except to the extent that such Non-U.S. Lender's assignor (if any) was entitled, at the time of assignment, to receive additional amounts from the Borrower with
respect to such Tax pursuant to Section 4.7(a) and (d) in the case of a Non-U.S. Lender, any Tax that is attributable
to such Non-U.S. Lender's failure or inability to comply with Section 4.7(e). 

        "Existing Commitment Termination Date" has the meaning set forth in Section 3.4(a). 

        "Existing Credit Agreement" has the meaning set forth in the recitals. 

        "Existing Lenders" has the meaning set forth in the recitals. 

        "Existing Letter of Credit" has the meaning set forth in Section 2.6.11. 

        "Exposure" means, with respect to any Lender at any time, the sum of the outstanding principal amount of such Lender's Loans and
LC Exposure at such time. 

        "Extension Date" has the meaning set forth in Section 3.4(a). 

        "Extension Request" has the meaning set forth in Section 3.4(a). 

        "Facilities" means (a) certain electric generation facilities and other related assets associated therewith and ancillary thereto
located in the State of Illinois acquired by the Borrower pursuant to the Asset Sale Agreement dated as of April 22, 1999 between Commonwealth Edison Company and EME, as amended, supplemented,
amended and restated or otherwise modified and in effect from time to time, as assigned by EME and (b) any other electric generation facilities and other related assets associated therewith and
ancillary thereto (or interests therein) owned, directly or indirectly, or leased by the Borrower from time to time. 

        "Federal Funds Effective Rate" means, for any day, the weighted average (rounded upwards, if necessary, to the next 1/100 of 1%) of the
rates on overnight Federal funds transactions with members of the Federal Reserve System arranged by Federal funds brokers, as published on the next succeeding Business Day by the Federal Reserve Bank
of New York, or, if such rate is not so published for any day that is a Business Day, the average (rounded upwards, if necessary, to the next 1/100 of 1%) of the quotations for such day for
such transactions received by the Administrative Agent from three Federal funds brokers of recognized standing selected by it. 

        "Fee Letters" means (a) the Fee Letter dated as of June 29, 2007 between the Borrower and Union Bank of California, N.A., as
amended, supplemented, amended and restated or otherwise modified and in effect from time to time; (b) the Fee Letter dated as of June 29, 2007 between the Borrower and J.P. Morgan
Securities Inc. and JPMorgan Chase Bank, N.A., as amended, supplemented, amended and restated or otherwise modified and in effect from time to time; and (c) each Fee Letter between the
Borrower and any Issuing Lender, as each such Issuing Lender Fee Letter may be amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

Third Amended and Restated Credit Agreement

10

 

        "Financing" means, with respect to any Person, either Indebtedness of such Person or Lease Obligations of such Person, or a combination
of both. 

        "Fiscal Quarter" means any quarter of a Fiscal Year. 

        "Fiscal Year" means any period of twelve consecutive calendar months ending on December 31; references to a Fiscal Year with a
number corresponding to any calendar year (e.g., the "2007 Fiscal Year") refers to the Fiscal Year ending on December 31 occurring during such
calendar year. 

        "Fisk Facility" means the Fisk station, 326 MW net coal-fired electric generating facility and related assets owned by
the Borrower, including the Fisk Peaking Unit, and located in Cook County, Illinois. 

        "Fisk Peaking Unit" means the 163 MW (nominal summer rating) oil-fired Fisk peaking unit owned by the Borrower and
located in Cook County, Illinois. 

        "Fitch" means Fitch Ratings and its successors and assigns. 

        "GAAP" means generally accepted accounting principles in the United States. 

        "Governmental Approval" means any authorization, consent, approval, license, permit, exemption, filing or registration with any
Governmental Authority. 

        "Governmental Authority" means any nation or government, any state, provincial or other political subdivision thereof and any entity
exercising executive, legislative, judicial, regulatory or administrative functions of or pertaining to government. 

        "Granting Lender" has the meaning set forth in Section 10.11.1(e). 

        "Guarantee" means a guarantee other than by endorsement of negotiable instruments for collection in the ordinary course of business,
direct or indirect, in any manner including, by way of a pledge of assets or through letters of credit or reimbursement agreements in respect thereof, of all or any part of any Indebtedness (whether
arising by virtue of partnership arrangements, or by agreements to keep-well, to purchase assets, goods, securities or services, to take or pay or to maintain financial statement
conditions or otherwise). 

        "Hazardous Material" means: 

        (a)   any
"hazardous substance", as defined by any Environmental Law; 

        (b)   any
"hazardous waste", as defined by any Environmental Law; 

        (c)   any
petroleum product (including crude oil or any fraction thereof); or 

        (d)   any
pollutant or contaminant or hazardous, dangerous or toxic chemical, material, force or substance (including polychlorinated biphenyls, urea-formaldehyde
insulation, asbestos or radioactivity) that is regulated pursuant to or could give rise to liability under any Environmental Law. 

        "herein", "hereof", "hereto",
"hereunder" and similar terms contained in any Loan Document refer to such Loan Document as a whole and not to any particular Section, paragraph or
provision of such Loan Document. 

        "Holdings Collateral Agent" has the meaning set forth in each Powerton/Joliet Lease Participation Agreement. 

        "including" means including without limiting the generality of any description preceding such term, and, for purposes of each Loan
Document, the parties thereto agree that the rule of ejusdem generis

Third Amended and Restated Credit Agreement

11

 

shall
not be applicable to limit a general statement, which is followed by or referable to an enumeration of specific matters, to matters similar to the matters specifically mentioned. 

        "Indebtedness" of any Person means, without duplication: 

        (a)   all
indebtedness for borrowed money; 

        (b)   all
obligations issued, undertaken or assumed as the deferred purchase price of property or services which purchase price is due more than six months from the date of
incurrence of the obligation in respect thereof or is evidenced by a note or other instrument, except trade accounts arising in the ordinary course of business; 

        (c)   all
reimbursement obligations with respect to surety bonds, letters of credit (to the extent not collateralized with cash or Cash Equivalent Investments),
bankers' acceptances and similar instruments (in each case, whether or not matured); 

        (d)   all
obligations evidenced by notes, bonds, debentures or similar instruments, including obligations so evidenced incurred in connection with the acquisition of property,
assets or businesses; 

        (e)   all
indebtedness created or arising under any conditional sale or other title retention agreement, or incurred as financing, in either case with respect to property
acquired by the Person (even though the rights and remedies of the seller or bank under such agreement in the event of default are limited to repossession or sale of such property); 

        (f)    all
Capitalized Lease Liabilities and Operating Lease Liabilities; 

        (g)   all
net obligations of such Person in respect to Swap Agreements; 

        (h)   all
indebtedness referred to in clauses (a) through (g)
above secured by (or for which the holder of such indebtedness has an existing right, contingent or otherwise, to be secured by) any Lien upon or in property (including accounts and contracts
rights) owned by such Person, even though such Person has not assumed or become liable for the payment of such indebtedness; and 

        (i)    all
Contingent Liabilities. 

For
all purposes of this Agreement, the Indebtedness of any Person shall include the Indebtedness of any partnership or joint venture in which such Person is a general partner or a joint venturer. The
amount of any Indebtedness outstanding as of any date will be (i) the accreted value of such Indebtedness, in the case of any Indebtedness issued with original issue discount, (ii) the
principal amount of such Indebtedness, in the case of any other Indebtedness and (iii) in respect of Indebtedness of another Person secured by a Lien on the assets of such Person, the lesser of
(A) the fair market value of such asset at the date of determination and (B) the amount of Indebtedness of such other Person. 

        "Indemnified Parties" has the meaning set forth in Section 10.4(a). 

        "Indemnified Liabilities" has the meaning set forth in Section 10.4(a). 

        "Indemnified Taxes" means Taxes other than Excluded Taxes. 

        "Insolvency" means, with respect to any Multiemployer Plan, the condition that such plan is insolvent within the meaning of
Section 4245 of ERISA. 

        "Interest Period" means, relative to any LIBO Rate Loan, the period beginning on (and including) the date on which such LIBO Rate
Loan is made or continued as, or converted into, a LIBO Rate Loan pursuant to Section 2.3
or 2.4 and shall end on (but exclude) the day which numerically 

Third Amended and Restated Credit Agreement

12

 

corresponds
to such date one, two, three or six months thereafter (or, if such month has no numerically corresponding day, on the last Business Day of such month), in either case as the Borrower may
select in its relevant notice pursuant to Section 2.3 or 2.4;  provided, however, that (a) if such Interest Period would otherwise end on a day which is not a
Business Day, such Interest Period shall end on the next following Business Day (unless, if such Interest Period applies to LIBO Rate Loans, such next following Business Day is the first Business Day
of a calendar month, in which case such Interest Period shall end on the Business Day next preceding such numerically corresponding day) and (b) no Interest Period may end later than the
Commitment Termination Date. No Interest Period applicable to the Loans shall begin prior to the Closing Date. 

        "Interest Rate Hedging Agreement" means any agreement entered into by the Borrower or any of its Subsidiaries after the Closing Date in
the ordinary course of business and not for speculative purposes in order to effectively cap, collar or exchange interest rates (from fixed to floating rates, from one floating rate to another
floating rate or otherwise) with respect to any interest-bearing liability or investment of the Borrower or any of its Subsidiaries. 

        "Investment" means, relative to any Person: 

        (a)   any
loan or advance made by such Person to any other Person (excluding commission, travel and similar advances to officers and employees made in the ordinary course
of business); 

        (b)   any
Contingent Liability of such Person; and 

        (c)   any
ownership or similar interest held by such Person in any other Person. 

The
amount of any Investment shall be the original principal or capital amount thereof less all returns of principal or equity thereon (and without adjustment by reason of the financial
condition of such other Person) and shall, if made by the transfer or exchange of property other than cash, be deemed to
have been made in an original principal or capital amount equal to the fair market value of such property. 

        "Investment Grade" means, with respect to any Person, no fewer than two of the following Rating Agencies have provided Debt Ratings of
such Person of at least BBB- by S&P, Baa3 by Moody's and BBB- by Fitch, respectively. 

        "Issuance Date" means the date on which a Letter of Credit is Issued pursuant to  Section 2.6. 

        "Issue" means, with respect to any Letter of Credit, to issue or to extend the expiry of, to amend or to renew or to increase the amount
of, such Letter of Credit; and the terms "Issued", "Issuing" and
"Issuance" have corresponding meanings. 

        "Issuing Lenders" means (a) JPMCB in its capacity as the issuer of Letters of Credit hereunder, (b) CNAI in its capacity as
the issuer of the Existing Letter of Credit which, in accordance with Section 2.6.11, is a Letter of Credit hereunder and (c) each other
Person as may have subsequently been appointed as a successor or an additional Issuing Lender pursuant to Section 2.6.9. 

        "Joliet #9 Facility" means the Joliet station, Unit 6, 314 MW of the 1,358 MW coal-fired electric
generating facility and certain related assets owned by the Borrower, including the Joliet Peaking Unit, and located on the parcel of real property known as Joliet #9 in Will County, Illinois.
For the avoidance of doubt, the Joliet #9 Facility does not include the Joliet Leased Facility. 

        "Joliet Equity Financing Parties I" means, collectively, the Equity Investor, the Owner Participant and the OP Guarantor (each as defined
in the Joliet Lease Participation Agreement (T1)). 

Third Amended and Restated Credit Agreement

13

 

        "Joliet Equity Financing Parties II" means, collectively, the Equity Investor, the Owner Participant and the OP Guarantor (each as defined
in the Joliet Lease Participation Agreement (T2)). 

        "Joliet Guarantee (T1)" means the Guaranty Agreement dated as of July 31, 2002 made by EME in favor of Joliet Trust I
that, among other things, guarantees the payment by the Borrower of all Joliet Lease Liabilities (T1) payable to Joliet Trust I, as amended, supplemented, amended and restated or
otherwise modified and in effect from time to time. 

        "Joliet Guarantee (T1: Equity Financing Parties)" means the Guaranty Agreement dated as of July 31, 2002 made by EME in favor of
the Joliet Equity Financing Parties I that, among other things, guarantees the payment by the Borrower of certain Joliet Lease Liabilities (T1) payable to Joliet Equity Financing Parties I, as
amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Joliet Guarantee (T2)" means the Guaranty Agreement dated as of July 31, 2002 made by EME in favor of Joliet
Trust II that, among other things, guarantees the payment by the Borrower of all Joliet Lease Liabilities (T2) payable to Joliet Trust II, as amended, supplemented, amended and restated
or otherwise modified and in effect from time to time. 

        "Joliet Guarantee (T2: Equity Financing Parties)" means the Guaranty Agreement dated as of July 31, 2002 made by EME in favor of
the Joliet Equity Financing Parties II that, among other things, guarantees the payment by the Borrower of certain Joliet Lease Liabilities (T2) payable to Joliet Equity Financing Parties II,
as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Joliet Guarantees" means, collectively, the Joliet Guarantee (T1), the Joliet Guarantee (T2), the Joliet Guarantee (T1: Equity
Financing Parties) and the Joliet Guarantee (T2: Equity Financing Parties). 

        "Joliet Intercompany Note Pledge Agreement (T1)" means the Pledge Agreement (T1) dated as of August 17, 2000 between
the Borrower and the Holdings Collateral Agent relating to the pledge of the Joliet Lease Intercompany Note (T1), as amended, supplemented, amended and restated or otherwise modified and in
effect from time to time. 

        "Joliet Intercompany Note Pledge Agreement (T2)" means the Pledge Agreement (T2) dated as of August 17, 2000 between
the Borrower and the Holdings Collateral Agent relating to the pledge of the Joliet Lease Intercompany Note (T2), as amended, supplemented, amended and restated or otherwise modified and in
effect from time to time. 

        "Joliet Lease (T1)" means the Facility Lease Agreement (T1) dated as of August 17, 2000 between the Borrower and
Joliet Trust I, as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Joliet Lease (T2)" means the Facility Lease Agreement (T2) dated as of August 17, 2000 between the Borrower and
Joliet Trust II, as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Joliet Lease Intercompany Note (T1)" means the EME Note (as defined in the Joliet Lease Participation
Agreement (T1)) dated the Closing Date (as defined in the Joliet Lease Participation Agreement (T1)) evidencing the loan by the Borrower to EME of the proceeds of the Joliet Lease
Transaction (T1), as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

Third Amended and Restated Credit Agreement

14

 

        "Joliet Lease Intercompany Note (T2)" means the EME Note (as defined in the Joliet Lease Participation
Agreement (T2)) dated the Closing Date (as defined in the Joliet Lease Participation Agreement (T2)) evidencing the loan by the Borrower to EME of the proceeds of the Joliet Lease
Transaction (T2), as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Joliet Lease Intercompany Notes" means, collectively, the Joliet Lease Intercompany Note (T1) and the Joliet Lease Intercompany
Note (T2). 

        "Joliet Lease Liabilities" means, collectively, the Joliet Lease Liabilities (T1) and the Joliet Lease Liabilities (T2). 

        "Joliet Lease Liabilities (T1)" mean the basic rent, the supplemental rent, termination value or any other amount, liability or
obligation that the Borrower is obligated to pay under the Joliet Lease (T1) or the other Joliet Lease Operative Documents (T1). 

        "Joliet Lease Liabilities (T2)" mean the basic rent, the supplemental rent, termination value or any other amount, liability or
obligation that the Borrower is obligated to pay under the Joliet Leases (T2) or the other Joliet Lease Operative Documents (T2). 

        "Joliet Lease Operative Documents" means, collectively, the Joliet Lease Operative Documents (T1) and the Joliet Lease Operative
Documents (T2). 

        "Joliet Lease Operative Documents (T1)" means, collectively, the Operative Documents as defined in the Joliet Lease Participation
Agreement (T1). 

        "Joliet Lease Operative Documents (T2)" means, collectively, the Operative Documents as defined in the Joliet Lease Participation
Agreement (T2). 

        "Joliet Lease Participation Agreement (T1)" means the Participation Agreement (T1) dated as of August 17, 2000 by and
among the Borrower, EME, Joliet Trust I, Wilmington Trust Company, Joliet Generation I, the Lease Indenture Trustee named therein and the Pass Through Trustees named therein, as amended,
supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Joliet Lease Participation Agreement (T2)" means the Participation Agreement (T2) dated as of August 17, 2000 by and
among the Borrower, EME, Joliet Trust II, Wilmington Trust Company, Joliet Generation II, the Lease Indenture Trustee named therein and the Pass Through Trustees named therein, as amended,
supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Joliet Lease Participation Agreements" means, collectively, the Joliet Lease Participation Agreement (T1) and the Joliet Lease
Participation Agreement (T2). 

        "Joliet Lease Transaction" means, collectively, the Joliet Lease Transaction (T1) and the Joliet Lease Transaction (T2). 

        "Joliet Lease Transaction (T1)" means the transactions pursuant to the Joliet Lease Participation Agreement (T1) and the
Joliet Lease Operative Documents (T1) whereby the Borrower sold a 63.6% undivided interest in the Joliet Leased Facility to Joliet Trust I and Joliet Trust I leases such undivided
interest to the Borrower pursuant to the Joliet Lease (T1). 

        "Joliet Lease Transaction (T2)" means the transactions pursuant to the Joliet Lease Participation Agreement (T2) and the
Joliet Lease Operative Documents (T2) whereby the Borrower sold a 36.4% 

Third Amended and Restated Credit Agreement

15

 

undivided
interest in the Joliet Leased Facility to Joliet Trust II and Joliet Trust II leases such undivided interest to the Borrower pursuant to the Joliet Lease (T2). 

        "Joliet Lease Trusts" means, collectively, Joliet Trust I and Joliet Trust II. 

        "Joliet Leased Facility" means the Joliet station, Units 7 and 8, 1,044 MW of the 1,358 MW coal-fired electric
generating facility and certain related assets located in Will County, Illinois and more fully described in Exhibit B to each
Joliet Lease. 

        "Joliet Leases" means, collectively, the Joliet Lease (T1) and Joliet Lease (T2). 

        "Joliet Peaking Unit" means the 112 MW (nominal summer rating) gas- and oil-fired peaking unit owned by the
Borrower and located in Will County, Illinois. 

        "Joliet Shared Facilities Agreements" means, collectively, (a) the Shared Facilities Agreement No. 1 dated as of
August 17, 2000 between the Borrower and Joliet Trust I, (b) the Shared Facilities Agreement No. 2 dated as of August 17, 2000 between Joliet Trust I and the
Borrower, (c) the Shared Facilities Agreement No. 1 dated as of August 17, 2000 between the Borrower and Joliet Trust II and (d) the Shared Facilities Agreement
No. 2 dated as of August 17, 2000 between Joliet Trust II and the Borrower. 

        "Joliet Subordination Agreement (T1)" means the Subordination Agreement dated as of August 17, 2000 between Joliet
Trust I, the Owner Participant (as defined in the Joliet Lease Participation Agreement (T1)), the Lease Indenture Trustee (as defined in the Joliet Lease Participation
Agreement (T1)) and the Holdings Collateral Agent, as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Joliet Subordination Agreement (T2)" means the Subordination Agreement dated as of August 17, 2000 between Joliet
Trust II, the Owner Participant (as defined in the Joliet Lease Participation Agreement (T2)), the Lease Indenture Trustee (as defined in the Joliet Lease Participation
Agreement (T2)) and the Holdings Collateral Agent, as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Joliet Trust I" means Nesbitt Asset Recovery, Series C-1 (formerly known as Joliet Trust I), a Delaware
business trust. 

        "Joliet Trust II" means Joliet Trust II, a Delaware business trust. 

        "JPMCB" has the meaning set forth in the preamble. 

        "LC Collateral Account" means an account established in the name of the Borrower but under the exclusive dominion and control of
the Administrative Agent, which shall be a "securities account"
(as defined in Section 8-501(a) of the UCC) and, to the extent that credit balances not constituting "financial assets" (as defined in
Section 8-102(a)(9) of the UCC) are credited thereto, a "deposit account" (as defined in Section 8-102(a)(29) of the UCC). 

        "LC Disbursement" means a payment made by any Issuing Lender pursuant to a Letter of Credit. 

        "LC Exposure" means, at any time, the sum of (a) the aggregate undrawn
amount of all outstanding Letters of Credit at such time plus (b) the aggregate amount of all LC Disbursements that have not yet been
reimbursed by or on behalf of the Borrower at such time. The LC Exposure of any Lender at any time shall be its Percentage of the total LC Exposure at such time. 

        "Lease Obligations" means rent, supplemental rent, termination value, or a similar monetary obligation under, or pursuant to, a lease or
related documents in connection with a leveraged lease transaction (including Contingent Liabilities related thereto). 

Third Amended and Restated Credit Agreement

16

 

        "Lender" means a Lender with a Commitment, an outstanding Loan or an unreimbursed LC Disbursement. 

        "Letter of Credit" means any letter of credit issued pursuant to this Agreement and each letter of credit listed on  Schedule 2.6.11. 

        "Letter of Credit Application" has the meaning set forth in Section 2.6.1. 

        "Letter of Credit Documents" means, with respect to any Letter of Credit, collectively, any application therefor and any other agreements,
instruments, Guarantees or other documents (whether general in application or applicable only to such Letter of Credit) governing or providing for (a) the rights and obligations of the parties
concerned or at risk with respect to such Letter of Credit or (b) any collateral security for any of such obligations, each as the same may be amended, supplemented, amended and restated or
otherwise in effect from time to time. 

        "LIBO Rate" means, with respect to any LIBO Rate Loan for any Interest Period, the rate appearing on Page 3750 of the Telerate
Service (or on any successor or substitute page of such Service, or any successor to or substitute for such Service, providing rate quotations comparable to those currently
provided on such page of such Service, as determined by the Administrative Agent from time to time for purposes of providing quotations of interest rates applicable to dollar deposits in the London
interbank market) at approximately 11:00 a.m., London time, two Business Days prior to the commencement of such Interest Period, as the rate for dollar deposits with a maturity comparable to
such Interest Period. In the event that such rate is not available at such time for any reason, then the "LIBO Rate" with respect to such LIBO Rate Loan
for such Interest Period shall be the rate at which dollar deposits of $5,000,000 and for a maturity comparable to such Interest Period are offered by the principal London office of the Administrative
Agent in immediately available funds in the London interbank market at approximately 11:00 a.m., London time, two Business Days prior to the commencement of such Interest Period. 

        "LIBO Rate Loan" means a Loan bearing interest, at all times during an Interest Period applicable to such Loan at a fixed rate of interest
per annum determined by reference to the Adjusted LIBO Rate plus the Applicable Margin for LIBO Rate Loans from time to time in effect. 

        "LIBOR Office" means, relative to any Lender, the office of such Lender designated as such on  Schedule 1.1(a) or designated in the Administrative Questionnaire
of such Lender or the Assignment Agreement or such other office of a
Lender as designated from time to time by notice from such Lender to the Borrower and the Administrative Agent pursuant to Section 4.4, whether
or not outside the United States, which shall be making or maintaining LIBO Rate Loans of such Lender hereunder. 

        "Lien" means any security interest, mortgage, pledge, hypothecation, assignment, deposit arrangement, encumbrance, lien (statutory or
otherwise), charge against or interest in property, in each case of any kind, to secure payment of a debt or performance of an obligation. 

        "Loan" has the meaning set forth in Section 2.1.2. 

        "Loan Documents" means (a) this Agreement, (b) the Security Documents, (c) the Communications Agreement,
(d) the Fee Letters, (e) the Letter of Credit Documents, (f) each Subsidiary Guarantee executed and delivered pursuant to  Section 7.1.8(d) and (g) the other agreements,
documents and instruments delivered in connection with this Agreement, including each
Borrowing Request and each Continuation/ Conversion Notice. 

        "Maintained Facilities" means (a) any Facility that is part of a Mortgaged Facility, (b) the Powerton Leased Facility and
(c) the Joliet Leased Facility. 

Third Amended and Restated Credit Agreement

17

   
        "Master Purchase Agreement" means the Amended and Restated Master Purchase, Sale and Services Agreement dated as of April 27, 2004
between the Borrower and EMMT, as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Material Adverse Effect" means any event, development or circumstance that has had or would reasonably be expected to have a material
adverse effect on (a) the business, assets, property, condition (financial or otherwise) or operations of the Borrower and its Subsidiaries, taken as a whole since the Closing Date,
(b) the ability of the Borrower or any of its Subsidiaries to perform its obligations under any of the Loan Documents to which it is a party or (c) the aggregate value of the Collateral
or the validity, enforceability or priority of the security interests granted in favor of the Lenders pursuant to the Security Documents granting a security interest in the Collateral. 

        "MGE" means Midwest Generation EME LLC, a Delaware limited liability company. 

        "MGE Pledge Agreement" means the Pledge Agreement dated as of April 27, 2004 between MGE and the Collateral Trustee, as amended,
supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Midwest Finance" means Midwest Finance Corp., a Delaware corporation. 

        "Midwest Related Party" means each of EMMH and MGE. 

        "Midwest Trading Revolver" means the Credit Agreement dated as of April 27, 2004 between the Borrower and EMMT, as amended,
supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Moody's" means Moody's Investors Service, a division of Dun & Bradstreet Corporation, and its successors and assigns. 

        "Mortgaged Facilities" means the Crawford Facility, the Fisk Facility, the Waukegan Facility, the Joliet #9 Facility and the Will
County Facility together with any and all easements benefiting any of the foregoing. 

        "Mortgaged Facility Mortgages" means (a) the Mortgage, Assignment of Rents and Leases, Fixture Filing, Financing Statement and
Security Agreement with respect to the Crawford Facility dated as of April 27, 2004, (b) the Mortgage, Assignment of Rents and Leases, Fixture Filing, Financing Statement and Security
Agreement with respect to the Fisk Facility dated as of April 27, 2004, (c) the Mortgage, Assignment of Rents and Leases, Fixture Filing, Financing Statement and Security Agreement with
respect to the Waukegan Facility dated as of April 27, 2004, (d) the Mortgage, Assignment of Rents and Leases, Fixture Filing, Financing Statement and Security Agreement with respect to
the Joliet #9 Facility dated as of April 27, 2004 and (e) the Mortgage, Assignment of Rents and Leases, Fixture Filing, Financing Statement and Security Agreement with respect to
the Will County Facility dated as of April 27, 2004. 

        "Multiemployer Plan" means a "multiemployer plan" as such term is defined in Section 4001(a)(3) of ERISA. 

        "MW" means megawatts. 

        "Necessary Capital Expenditures" means capital expenditures that, in the exercise of Prudent Industry Practices, are reasonably necessary
for the continued operation or maintenance of the Facilities or are required by applicable law (other than Environmental Laws). The term "Necessary Capital Expenditures" does not include any capital
expenditure undertaken primarily to increase the efficiency of, expand or re-power the Facilities. 

Third Amended and Restated Credit Agreement

18

 

        "Non-Core Facilities" means the Facilities other than the Core Facilities. 

        "Non-Recourse Persons" means Edison International, Edison Mission Group, EME, Mission Energy Holding Company and Southern
California Edison Company, and each of their Affiliates (except as provided herein) and the officers, directors, employees, shareholders (except as aforesaid), agents, Authorized Representatives and
other controlling persons (except as aforesaid) of
the Borrower, provided that in no event shall the Borrower be deemed to be a Non-Recourse Person and provided
further that each Midwest Related Party and EMMT shall be a Non-Recourse Person except with respect to, and to the extent, of the Collateral furnished thereby under
the Security Documents to which it is a party and as otherwise provided in such Security Documents. 

        "Non-U.S. Lender" has the meaning set forth in Section 4.7(e). 

        "Notes" mean the 8.75% Second Priority Senior Secured Notes in an aggregate principal amount of $1,000,000,000 issued on the date of and
pursuant to the Indenture, dated as of April 27, 2004, among the Borrower, Midwest Finance and The Bank of New York, as Trustee, as supplemented or otherwise modified and in effect from
time to time. 

        "NUG Contingent Liabilities" means Contingent Liabilities of EMMT existing as of the Closing Date in connection with (a) the
disaggregation of the New England Power Pool and (b) agreements existing as of the Closing Date relating to the NUG Trading Entities, Newhall Funding Company and Athens
Funding, LLC. 

        "NUG Trading Entities" means CL Power Sales One, L.L.C., CL Power Sales Two, L.L.C., CL Power Sales Three, L.L.C., CL Power Sales Seven,
L.L.C., CL Power Sales Eight, L.L.C., CL Power Sales Nine, L.L.C., CL Power Sales Ten, L.L.C., CP Power Sales Twelve, L.L.C., CP Power Sales Sixteen, L.L.C. and CP Power Sales Seventeen, L.L.C. 

        "Obligations" means with respect to any Indebtedness of any Person (collectively, without duplication): (a) all debt, financial
liabilities and obligations of such Person of whatsoever nature and howsoever evidenced (including principal, interest, fees, reimbursement obligations, cash cover obligations, penalties, indemnities
and legal and other expenses, whether due after acceleration or otherwise) to the providers or holders of such Indebtedness or to any agent, trustee or other representative of such providers or
holders of such Indebtedness under or pursuant to each agreement, document or instrument evidencing, securing, Guaranteeing or relating to such Indebtedness, financial liabilities or obligations
relating to such Indebtedness (including Loan Documents applicable to such Indebtedness (if any)), in each case, direct or indirect, primary or secondary, fixed or contingent, now or hereafter
arising out of or relating to any such agreement, document or instrument; (b) any and all sums advanced by the Collateral Trustee or any other Person in order to preserve the Collateral or any
other collateral securing such Indebtedness or to preserve the Liens and security interests in the Collateral or any other collateral, securing such Indebtedness; and (c) the costs and expenses
of collection and enforcement of the obligations referred to in clauses (a) and (b)
(including (i) the costs and expenses of retaking, holding, preparing for sale or lease, selling or otherwise disposing of or realizing on any Collateral or any other collateral,
(ii) the costs and expenses of any exercise by the Collateral Trustee or any other Person of its rights under the Security Documents or any other security documents and (iii) reasonable
attorneys' fees and court costs). 

        "Officer's Certificate" means a certificate with respect to compliance with a condition or covenant provided for in this Agreement, signed
on behalf of the Borrower by two Authorized Representatives of 

Third Amended and Restated Credit Agreement

19

 

the
Borrower, one of whom must be the principal executive officer, the principal financial officer, the treasurer or the principal accounting officer of the Borrower, including: 

        (a)   a
statement that the Authorized Representative making such certificate or opinion has read such covenant or condition; 

        (b)   a
brief statement as to the nature and scope of the examination or investigation upon which the statements or opinions contained in such certificate or opinion
are based; 

        (c)   a
statement that, in the opinion of such Authorized Representative, he or she has made such examination or investigation as is necessary to enable him or her to express
an informed opinion as to whether or not such covenant or condition has been satisfied; and 

        (d)   a
statement as to whether or not, in the opinion of such Authorized Representative, such condition or covenant has been satisfied. 

        "Operating Lease" means any lease other than a Capital Lease. 

        "Operating Lease Liability" of any Person means all monetary obligations of such Person under any Operating Lease, and, for purposes of
each Loan Document, the amount of such obligations shall be the termination value of such Operating Lease; provided,  however, that for purposes of
Section 7.2.1(a) and  Schedule 7.2.1(a) the amount of such obligations shall be the aggregate future payments due under such Operating Lease.

        "Operation" has the meaning set forth in Section 6.10(b). 

        "Organic Document" means, with respect to any Person that is a corporation, its certificate of incorporation, its by-laws and
all shareholder agreements, voting trusts and similar arrangements applicable to any of its authorized shares of capital stock; with respect to any Person that is a limited liability company, its
certificate of formation and its limited liability agreement, and, with
respect to a private limited liability company, its deed of incorporation, its articles of association, all shareholders agreements, if any, and the shareholders register in each case, as from time to
time amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Original Effective Date" means April 27, 2004. 

        "Other Taxes" means any and all present or future stamp or documentary Taxes or any other excise or property Taxes, charges or similar
levies arising from any payment made under any Loan Document or from the execution, delivery or enforcement of, or otherwise with respect to, any Loan Document. 

        "Parity Lien Debt" has the meaning set forth in the Collateral Trust Agreement. 

        "Parity Lien Obligations" has the meaning set forth in the Collateral Trust Agreement. 

        "Participant" has the meaning set forth in Section 10.11.2. 

        "Participation Fee" has the meaning set forth in Section 3.3.2. 

        "PBGC" means the Pension Benefit Guaranty Corporation and any entity succeeding to any or all of its functions under ERISA. 

        "Pension Plan" means a "pension plan", as such term is defined in Section 3(2) of ERISA, which is subject to Title IV of ERISA
(other than a multiemployer plan as defined in Section 4001(a)(3) of ERISA), and to which the Borrower or any corporation, trade or business that is, along with the Borrower, a member of a
Controlled Group, has any liability, including any liability by reason of having been a substantial employer within the meaning of Section 4063 of ERISA at any time during the 

Third Amended and Restated Credit Agreement

20

 

preceding
five years, or by reason of being deemed to be a contributing sponsor under Section 4069 of ERISA. 

        "Percentage" means, at any time of determination with respect to any Lender, the sum of the amount of such Lender's Exposure and unused
Commitments at such time divided by the sum of the total amount of Exposure and unused Commitments at such time. 

        "Permitted Hedge Counterparty" means (i) with respect to any Commodity Hedge and Power Sales Agreement, any Person (other than the
Borrower or any of its Subsidiaries) that is a party to such Commodity Hedge and Power Sales Agreement; and (ii) with respect to any Interest Rate Hedging Agreement, any Person that is a Lender
or an Affiliate of a Lender at the time such Interest Rate Hedging Agreement is entered into or such other Person with the prior approval of the Required Lenders, such approval not to be unreasonably
withheld or delayed. 

        "Permitted Liens" means the liens permitted under Section 7.2.2. 

        "Permitted Marketing Support" shall mean the use by the Borrower of its funds, Priority Lien Debt, Parity Lien Debt or the proceeds of
Loans and Letters of Credit, in each case, to support Commodity Hedge and Power Sales Agreements by or for the benefit of the Borrower, whether directly with unaffiliated third parties or
with EMMT. 

        "Permitted Refinancing Indebtedness" means any Indebtedness of the Borrower or any of its Affiliates issued in exchange for, or the net
proceeds of which are used to Refinance other Indebtedness of the Borrower or any of its Subsidiaries (other than intercompany Indebtedness);  provided, that: 

        (a)   the
aggregate principal amount (or accreted value, if applicable) of such Permitted Refinancing Indebtedness does not exceed the aggregate principal amount
(or accreted value, if applicable) of the Indebtedness Refinanced (plus all accrued interest on the Indebtedness and the amount of all fees and
expenses, including premiums, incurred in connection therewith); 

        (b)   such
Permitted Refinancing Indebtedness has a final maturity date later than the final maturity date of, and has a Weighted Average Life to Maturity equal to or greater
than the Weighted Average Life to Maturity of, the Indebtedness being Refinanced; provided, that with respect to any Capitalized Lease Liabilities, the
final maturity date thereof, for purposes of this definition and the definition of "Weighted Average Life to Maturity" shall be the earlier of (i) the expiration of such Capitalized Lease
Liabilities and (ii) the final maturity date of any Indebtedness underlying such Capitalized Lease Liabilities; and 

        (c)   if
the Indebtedness being Refinanced is subordinated in right of payment to the Loans, such Permitted Refinancing Indebtedness has a final maturity date later than the
final maturity date of, and is subordinated in right of payment to, the Loans on terms at least as favorable to the Lenders as those contained in the documentation governing the Indebtedness being
Refinanced. 

        "Permitted Tax Payment" means, with respect to the Borrower and its Subsidiaries, without duplication as to amounts, (a) any
payment of United States Federal, state, local or foreign taxes required to be paid by the Borrower or its Subsidiaries and (b) any payments required by any tax allocation or similar
agreements existing as of the Closing Date or any amendment or modification thereto, so long as such amendment, modification or waiver (i) does not result in such tax allocation or similar
agreement requiring payments of the Borrower and its Subsidiaries in excess of United States Federal, state, local or foreign taxes attributable to the Borrower and its Subsidiaries or
(ii) would otherwise cause a Material Adverse Effect. 

Third Amended and Restated Credit Agreement

21

 

        "Person" means any natural person, corporation, partnership, limited liability company, firm, association, trust, government, governmental
agency or any other entity, whether acting in an individual, fiduciary or other capacity. 

        "Pledge Agreements" means (a) the MGE Pledge Agreement and (b) the EMMH Pledge Agreement. 

        "Powerton Equity Financing Parties I" means, collectively, the Equity Investor, the Owner Participant and the OP Guarantor (each as
defined in the Powerton Lease Participation Agreement (T1)). 

        "Powerton Equity Financing Parties II" means, collectively, the Equity Investor, the Owner Participant and the OP Guarantor (each
as defined in the Powerton Lease Participation Agreement (T2)). 

        "Powerton Guarantee (T1)" means the Guaranty Agreement dated as of July 31, 2002 made by EME in favor of Powerton
Trust I that, among other things, guarantees the payment by the Borrower of all Powerton Lease Liabilities (T1) payable to Powerton Trust I, as amended, supplemented, amended and
restated or otherwise modified and in effect from time to time. 

        "Powerton Guarantee (T1: Equity Financing Parties)" means the Guaranty Agreement dated as of July 31, 2002 made by EME in favor of
the Powerton Equity Financing Parties I that, among other things, guarantees the payment by the Borrower of certain Powerton Lease Liabilities (T1) payable to Powerton Equity Financing
Parties I, as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Powerton Guarantee (T2)" means the Guaranty Agreement dated as of July 31, 2002 made by EME in favor of Powerton
Trust II that, among other things, guarantees the payment by the Borrower of all
Powerton Lease Liabilities (T2) payable to Powerton Trust II, as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Powerton Guarantee (T2: Equity Financing Parties)" means the Guaranty Agreement dated as of July 31, 2002 made by EME in favor of
the Powerton Equity Financing Parties II that, among other things, guarantees the payment by the Borrower of certain Powerton Lease Liabilities (T2) payable to Powerton Equity Financing
Parties II, as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Powerton Guarantees" means, collectively, the Powerton Guarantee (T1), the Powerton Guarantee (T2), the Powerton Guarantee
(T1: Equity Financing Parties) and the Powerton Guarantee (T2: Equity Financing Parties). 

        "Powerton Intercompany Note Pledge Agreement (T1)" means the Pledge Agreement (T1) dated as of August 17, 2000 among
the Borrower and the Holdings Collateral Agent relating to the pledge of the Powerton Lease Intercompany Note (T1), as amended, supplemented, amended and restated or otherwise modified and in
effect from time to time. 

        "Powerton Intercompany Note Pledge Agreement (T2)" means the Pledge Agreement (T2) dated as of August 17, 2000 among
the Borrower and the Holdings Collateral Agent relating to the pledge of the Powerton Lease Intercompany Note (T2), as amended, supplemented, amended and restated or otherwise modified and in
effect from time to time. 

        "Powerton Lease (T1)" means the Facility Lease Agreement (T1) dated as of August 17, 2000 between the Borrower and
Powerton Trust I, as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

Third Amended and Restated Credit Agreement

22

 

        "Powerton Lease (T2)" means the Facility Lease Agreement (T2) dated as of August 17, 2000 between the Borrower and
Powerton Trust II, as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Powerton Lease Intercompany Note (T1)" means the EME Note (as defined in the Powerton Lease Participation
Agreement (T1)) dated the Closing Date (as defined in the Powerton Lease Participation Agreement (T1)) evidencing the loan by the Borrower to EME of the proceeds of the Powerton
Lease
Transaction (T1), as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Powerton Lease Intercompany Note (T2)" means the EME Note (as defined in the Powerton Lease Participation
Agreement (T2)) dated the Closing Date (as defined in the Powerton Lease Participation Agreement (T2)) evidencing the loan by the Borrower to EME of the proceeds of the Powerton
Lease Transaction (T2), as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Powerton Lease Intercompany Notes" means, collectively, the Powerton Lease Intercompany Note (T1) and the Powerton Lease
Intercompany Note (T2). 

        "Powerton Lease Liabilities" means, collectively, the Powerton Lease Liabilities (T1) and the Powerton Lease
Liabilities (T2). 

        "Powerton Lease Liabilities (T1)" mean the basic rent, the supplemental rent, termination value or any other amount, liability or
obligation that the Borrower is obligated to pay under the Powerton Lease (T1) or the other Powerton Lease Operative Documents (T1). 

        "Powerton Lease Liabilities (T2)" mean the basic rent, the supplemental rent, termination value or any other amount, liability or
obligation that the Borrower is obligated to pay under the Powerton Lease (T2) or the other Powerton Lease Operative Documents (T2). 

        "Powerton Lease Operative Documents" means, collectively, the Powerton Lease Operative Documents (T1) and the Powerton Lease
Operative Documents (T2). 

        "Powerton Lease Operative Documents (T1)" means, collectively, the Operative Documents as defined in the Powerton Lease
Participation Agreement (T1). 

        "Powerton Lease Operative Documents (T2)" means, collectively, the Operative Documents as defined in the Powerton Lease
Participation Agreement (T2). 

        "Powerton Lease Participation Agreement (T1)" means the Participation Agreement (T1) dated as of August 17, 2000 by
and among the Borrower, EME, Powerton Trust I, Wilmington Trust Company, Powerton Generation I, the Lease Indenture Trustee named therein and the Pass Through Trustees
named therein, as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Powerton Lease Participation Agreement (T2)" means the Participation Agreement (T2) dated as of August 17, 2000 by
and among the Borrower, EME, Powerton Trust II, Wilmington Trust Company, Powerton Generation II, the Lease Indenture Trustee named therein and the Pass Through Trustees named therein, as
amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Powerton Lease Participation Agreements" means, collectively, the Powerton Lease Participation Agreement (T1) and the Powerton
Lease Participation Agreement (T2). 

Third Amended and Restated Credit Agreement

23

 

        "Powerton Lease Transaction" means, collectively, the Powerton Lease Transaction (T1) and the Powerton Lease
Transaction (T2). 

        "Powerton Lease Transaction (T1)" means the transactions pursuant to the Powerton Lease Participation Agreement (T1) and the
Powerton Lease Operative Documents (T1) whereby the Borrower sells a 63.6% undivided interest in the Powerton Leased Facility to Powerton Trust I and Powerton Trust I leases such
undivided interest to the Borrower pursuant to the Powerton Lease (T1). 

        "Powerton Lease Transaction (T2)" means the transactions pursuant to the Powerton Lease Participation Agreement (T2) and the
Powerton Lease Operative Documents (T2) whereby the Borrower sells a 36.4% undivided interest in the Powerton Leased Facility to Powerton Trust II and Powerton Trust II leases such
undivided interest to the Borrower pursuant to the Powerton Lease (T2). 

        "Powerton Lease Trusts" means, collectively, Powerton Trust I and Powerton Trust II. 

        "Powerton Leased Facility" means the Powerton station, 1,538 MW coal-fired electric generating facility and certain
related assets located in Tazewell County, Illinois and more fully described in Exhibit B to each Powerton Lease. 

        "Powerton Leases" means, collectively, the Powerton Lease (T1) and Powerton Lease (T2). 

        "Powerton Subordination Agreement (T1)" means the Subordination Agreement dated as of August 17, 2000 between Powerton
Trust I, the Owner Participant (as defined in the Powerton Lease Participation Agreement (T1)), the Lease Indenture Trustee (as defined in the Powerton Lease Participation
Agreement (T1)) and the Holdings Collateral Agent, as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Powerton Subordination Agreement (T2)" means the Subordination Agreement dated as of August 17, 2000 between Powerton
Trust II, the Owner Participant (as defined in the Powerton Lease Participation Agreement (T2)), the Lease Indenture Trustee (as defined in the Powerton Lease Participation
Agreement (T2)) and the Holdings Collateral Agent, as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Powerton Trust I" means Nesbitt Asset Recovery, Series P-1 (formerly known as Powerton Trust I), a
Delaware business trust. 

        "Powerton Trust II" means Powerton Trust II, a Delaware business trust. 

        "Powerton/Joliet Intercompany Note Pledge Agreements" means, collectively, the Powerton Intercompany Note Pledge Agreement (T1),
the Powerton Intercompany Note Pledge Agreement (T2), the Joliet Intercompany Note Pledge Agreement (T1) and the Joliet Intercompany Note Pledge Agreement (T2). 

        "Powerton/Joliet Lease Assets" means, collectively, the Powerton Leased Facility and the Joliet Leased Facility. 

        "Powerton/Joliet Lease Guarantees" means, collectively, the Powerton Guarantees, the Joliet Guarantees and the Powerton/Joliet
Reimbursement Agreement. 

        "Powerton/Joliet Lease Intercompany Notes" means, collectively, the Powerton Lease Intercompany Notes and the Joliet Lease Intercompany
Notes. 

        "Powerton/Joliet Lease Liabilities" means, collectively, the Powerton Lease Liabilities and the Joliet Lease Liabilities. 

Third Amended and Restated Credit Agreement

24

 

        "Powerton/Joliet Lease Operative Documents" means, collectively, the Powerton Lease Operative Documents and the Joliet Lease Operative
Documents. 

        "Powerton/Joliet Lease Participation Agreements" means, collectively, the Powerton Lease Participation Agreement (T1), Powerton
Lease Participation Agreement (T2), Joliet Lease Participation Agreement (T1) and Joliet Lease Participation Agreement (T2). 

        "Powerton/Joliet Lease Transaction" means, collectively, the Powerton Lease Transaction and the Joliet Lease Transaction. 

        "Powerton/Joliet Lease Trusts" means, collectively, the Powerton Lease Trusts and the Joliet Lease Trusts. 

        "Powerton/Joliet Leases" means, collectively, Powerton Leases and Joliet Leases. 

        "Powerton/Joliet Reimbursement Agreement" means the Reimbursement Agreement dated as of August 17, 2000 between EME and the
Borrower, as amended, supplemented, amended and restated or otherwise modified and in effect from time to time. 

        "Powerton/Joliet Subordination Agreements" means, collectively, the Powerton Subordination Agreement (T1), the Powerton
Subordination Agreement (T2), the Joliet Subordination Agreement (T1) and the Joliet Subordination Agreement (T2). 

        "Pricing Grid" means the pricing grid set forth on Schedule 3.2.1. 

        "Prime Rate" means the rate of interest per annum publicly announced from time to time by JPMCB as its prime rate in effect at its office
at 270 Park Avenue, New York, New York; each change in the Prime Rate shall be effective from and including the date such change is publicly announced as being effective. 

        "Priority Debt Representative" has the meaning set forth in the Collateral Trust Agreement. 

        "Priority Debt Sharing Confirmation" has the meaning set forth in the Collateral Trust Agreement. 

        "Priority Lien Debt" means: 

        (a)   (i)
the Indebtedness under this Agreement in an amount not to exceed $500,000,000, (ii) Indebtedness incurred to finance Necessary Capital Expenditures in an
aggregate amount not to exceed $50,000,000, (iii) Indebtedness under any Eligible Commodity Hedge and Power Sale Agreement entered into in accordance with this Agreement and (iv) all
other Priority Lien Obligations; and 

        (b)   Permitted
Refinancing Indebtedness to Refinance Priority Lien Debt. 

        "Priority Lien Obligations" means the Priority Lien Debt and all other Obligations in respect of Priority Lien Debt. 

        "Priority Lien Secured Parties" has the meaning set forth in the Collateral Trust Agreement. 

        "Pro Forma" means, with respect to a calculation required to be made pursuant to this Agreement, that such calculation is made in
accordance with the methodologies set forth in Regulation S-X under the Securities Act and gives effect to all relevant modifications to contractual arrangements that have been made
prior to, or are being made on, the calculation date; provided, that in the case of a calculation for any period occurring prior to the Closing Date,
all contractual arrangements in effect on the Closing Date shall be deemed to have been in effect for the entirety of such period. 

Third Amended and Restated Credit Agreement

25

   
        "Prudent Industry Practice" means, at a particular time, (a) any of the practices, methods and acts engaged in or approved by a
significant portion of the competitive electric generating industry at such time, or (b) with respect to any matter to which clause (a)
does not apply, any of the practices, methods and acts which, in the exercise of reasonable judgment at the time the decision was made, could have been expected to accomplish the desired result at a
reasonable cost consistent with good business practices, reliability, safety and expedition. "Prudent Industry Practice" is not intended to be limited to the optimum practice, method or act to the
exclusion of all others, but rather to be a spectrum of possible practices, methods or acts having due regard for, among other things, manufacturers' warranties and the requirements of any
Governmental Authority of competent jurisdiction. 

        "PUHCA" means the Public Utility Holding Company Act of 2005, as amended. 

        "Quarterly Payment Date" means the first day of each January, April, July and October or, if any such day is not a Business Day, the next
succeeding Business Day. 

        "Rating Agency" means (a) S&P, (b) Moody's, (c) Fitch or (d) if none of the foregoing shall exist, a
"nationally recognized statistical rating organization," as that term is defined in regulations promulgated by the SEC or as that term is interpreted by the SEC. 

        "Refinance" means with respect to any Financing, extensions, refinancing, renewal, replacement, defeasance or refund of such Financing
for, or with the proceeds of, other Indebtedness. 

        "Register" has the meaning set forth in Section 10.11.1(b). 

        "Regulatory Violation" means (a) the Borrower or any of its Subsidiaries becoming subject to regulation as a "public utility" under
the laws of the State of Illinois or (b) the Borrower failing (i) to be interconnected with the high voltage network or to have access to transmission services and ancillary services to
sell wholesale electric power or (iii) to have the authority to sell wholesale electric power at
market-based rates and, in the case of clause (a) or (b), such circumstance could
reasonably be expected to result in a Material Adverse Effect. 

        "Reorganization" means, with respect to any Multiemployer Plan, the condition that such plan is in reorganization within the meaning of
Section 4241 of ERISA. 

        "Reportable Event" means any of the events set forth in Section 4043(b) of ERISA, other than those events as to which the thirty
(30) day notice period is waived under subsections .13, .14, .16, .18, .19 or .20 of PBGC Reg. Section 2615. 

        "Required Lenders" means, at any time, subject to the last paragraph of  Section 10.1, Lenders having Exposure and unused Commitments representing at least 50.1% of
the sum of the total Exposure and unused and
outstanding Commitments at such time. 

        "Requirement of Law" means, as to any Person, the Organic Documents of such Person, and any law, treaty, rule or regulation or
determination of an arbitrator or a court or other authority, in each case, applicable to or binding upon such Person or any of its Property or to which such Person or any of its property
is subject. 

        "Restricted Payment" has the meaning set forth in Section 7.2.7. 

        "Retiring Lenders" has the meaning set forth in the recitals. 

        "S&P" means Standard & Poor's Ratings Services and its successors and assigns. 

        "SEC" means the United States Securities and Exchange Commission or any successor thereto. 

Third Amended and Restated Credit Agreement

26

 

        "Secured Parties" has the meaning set forth in the Collateral Trust Agreement. 

        "Securities Act" means the Securities Act of 1933, as amended. 

        "Security Documents" means (a) the Collateral Trust Agreement, (b) the Borrower Security Agreement, (c) each Pledge
Agreement, (d) the EMMT Security Agreement, (e) the Powerton/Joliet Subordination Agreements, (f) the Mortgaged Facility Mortgages and (g) any other agreement or instrument
hereafter entered into by the Borrower or any other Person which, directly or indirectly, Guarantees or secures payment of Indebtedness under this Agreement or payment or performance of any other
Obligation arising under a Loan Document. 

        "Solvent" means, with respect to any Person, on any date of determination: 

        (a)   the
fair market value of its assets is in excess of the total amount of its liabilities (including net contingent liabilities); 

        (b)   it
is then able and expects to be able to pay its debts as they mature; and 

        (c)   it
has capital sufficient to carry on its business as conducted and as proposed to be conducted. For purposes of the foregoing, the amount of contingent liabilities at
any time shall be computed as the amount that, in light of all the facts and circumstances existing at such time, can reasonably be expected to become an actual or matured liability. 

        "SPC" has the meaning set forth in Section 10.11.1(e). 

        "Specified Transaction" means, with respect to any Person (a) any prepaid forward sale of energy, capacity, oil, gas or minerals by
such Person that is intended primarily as a borrowing of funds, excluding volumetric production payments, and (b) any Swap Agreement or other derivative that is intended primarily as a
borrowing of funds, or any combination of any of the foregoing, with the amount of the obligations of such Person thereunder being the net obligations of such Person thereunder. 

        "Statutory Reserve Rate" means a fraction (expressed as a decimal), the numerator of which is the number one and the denominator of which
is the number one minus the aggregate of the maximum reserve percentages (including any marginal, special, emergency or supplemental reserves) expressed
as a decimal established by the Board to which the Administrative Agent is subject with respect to the Adjusted LIBO Rate, for eurocurrency funding (currently referred to as "Eurocurrency Liabilities"
in Regulation D of the Board). Such reserve percentages shall include those imposed pursuant to such Regulation D. LIBO Rate Loans shall be deemed to constitute eurocurrency funding and
to be subject to such reserve requirements without benefit of or credit for proration, exemptions or offsets that may
be available from time to time to any Lender under such Regulation D or any comparable regulation. The Statutory Reserve Rate shall be adjusted automatically on and as of the effective
date of any change in any reserve percentage. 

        "Subordinated Indebtedness" means Indebtedness of the Borrower or any of its Subsidiaries (other than Affiliated Indebtedness) that is
unsecured and/or contractually subordinated to Priority Lien Debt and Parity Lien Debt. 

        "Subsidiary" means, with respect to any Person: (a) any corporation, association or other business entity of which more than 50% of
the outstanding capital stock having ordinary voting power to elect a majority of the directors, managers or trustees of such corporation (irrespective of whether at the time capital stock of any
other class or classes of such corporation shall or might have voting power upon the occurrence of any contingency) is at the time directly or indirectly owned by such Person, by such Person and one
or more other Subsidiaries of such Person, or by one or more other Subsidiaries of 

Third Amended and Restated Credit Agreement

27

 

such
Person; and (b) any partnership (i) the sole general partner or the managing general partner of which is such Person or a Subsidiary of such Person or (ii) the only general
partners of which are such Person or one or more Subsidiaries of such Person (or any combination thereof). 

        "Subsidiary Guarantee" means a Subsidiary Guarantee substantially in the form of  Exhibit F between a Subsidiary of the Borrower and the Administrative Agent, as
amended, restated, amended and restated or otherwise modified and
in effect from time to time. 

        "Swap Agreement" means any Commodity Hedge and Power Sales Agreement, Interest Rate Hedging Agreement or any other agreement with respect
to any swap, forward, future or derivative transaction or option or similar agreement involving, or settled by reference to, one or more rates, currencies, commodities, equity or debt instruments or
securities, or economic, financial or pricing indices or measures of economic, financial or pricing risk or value or any similar transaction or any combination of these transactions. 

        "Tax" or "Taxes" means, with respect to any Person, any present or future taxes (including
income, gross receipts, license, payroll, employment, excise, severance, stamp, occupation, premium, windfall profits, environmental, capital stock, franchise, profits, withholding, social security
(or similar), unemployment, disability, real property, personal property, sales, use, transfer, registration, value-added, ad valorem, alternative or add-on minimum, estimated, or
other tax of any kind whatsoever), levies, imposts, duties, fees or charges imposed by any government or any governmental agency or instrumentality or any international or multinational agency or
commission, including any interest, penalty, or addition thereto, whether disputed or not for which such Person may be liable (including any such Tax related to any other Person for which such Person
is liable, by contract, as transferee or successor, by law or otherwise). 

        "Tax Return" means all returns, declarations, reports, claims for refund and information returns and statements of any Person required to
be filed with respect to, or in respect of, any Taxes, including any schedule or attachment thereto and any amendment thereof. 

        "Title Insurer" means Chicago Title Insurance Company. 

        "Title Policies" means the American Land Title Association 1970 (revised 10/17/84) Form extended coverage Lender's Fee Policies of title
insurance dated the date of recording of the Mortgaged Facility Mortgages issued by the Title Insurer insuring the Lien in favor of the Collateral Trustee for the benefit of the Secured Parties
created by the Mortgaged Facility Mortgages. 

        "Titled Institutions" means each financial institution named on the cover page to this Agreement as a "Joint Lead Arranger", "Joint
Bookrunner", "Syndication Agent", or "Co-Documentation Agent", in each case in its capacity as such. 

        "Transaction with an Affiliate" means, with respect to any Person (a) any agreement or contract with any Affiliate or Subsidiary of
such Person and any amendment, modification or supplement thereof or thereto or (b) any other transaction or business arrangement with an Affiliate or Subsidiary of such Person not otherwise
expressly permitted by the Loan Documents. 

        "type" means, relative to any Loan, the portion thereof, if any, being maintained as a Base Rate Loan or a LIBO Rate Loan. 

        "Uniform Commercial Code" or "UCC" means the Uniform Commercial Code as in effect from
time to time in the State of New York. 

        "United States" or "U.S." means the United States of America, its fifty
States and the District of Columbia. 

Third Amended and Restated Credit Agreement

28

 

        "United States Person" has the meaning given to such term in Section 7701(a)(30) of the Code. 

        "Voting Stock" of any Person as of any date means the Capital Stock of such Person that is at the time entitled to vote in the election of
the Board of Directors of such Person. 

        "Waukegan Facility" means the Waukegan station, 789 MW net coal-fired electric generating facility and related assets
owned by the Borrower, including the Waukegan Peaking Unit, and located in Lake County, Illinois. 

        "Waukegan Peaking Unit" means the 92 MW (nominal summer rating) oil-fired Waukegan peaking unit owned by the Borrower
and located in Lake County, Illinois. 

        "Waukegan Unit 6" means the 100 MW net coal-fired Unit 6 that is part of the Waukegan Facility. 

        "Weighted Average Life to Maturity" means, when applied to any Indebtedness at any date, the number of years obtained by dividing: 

        (a)   the
sum of the products obtained by multiplying (i) the amount of each then remaining installment, sinking fund, serial maturity or other required payments of
principal, including payment at final maturity, in respect of the Indebtedness, by (ii) the number of years (calculated to the nearest one-twelfth) that will elapse between such
date and the making of such payment; by 

        (b)   the
then outstanding principal amount of such Indebtedness. 

        "Welfare Plan" means a "welfare plan", as such term is defined in Section 3(1) of ERISA. 

        "Will County Facility" means the Will County station, 1,092 MW net coal-fired electric generating facility and related
assets owned by the Borrower and located in Will County, Illinois. 

        "Will County Units 1 and 2" means, collectively, (a) the 156 MW net coal-fired Unit 1 that is part of the
Will County Facility and (b) the 154 MW net coal-fired Unit 2 that is part of the Will County Facility. 

        SECTION 1.2    Use of Defined Terms.    Unless otherwise defined or the context otherwise requires, terms for
which meanings are provided in this Agreement shall have such meanings when used in each Borrowing Request, Continuation/Conversion Notice, Loan Document, notice and other communication delivered from
time to time in connection with any Loan Document. 

        SECTION 1.3    Cross-References.    Unless otherwise specified, references in this Agreement to any Article,
Section, Annex, Exhibit or Schedule are references to such Article, Section, Annex, Exhibit or Schedule of or to this Agreement, and, unless otherwise specified, references in any Article, Section or
definition to any clause are references to such clause of such Article, Section or definition. 

        SECTION 1.4    Accounting and Financial Determinations.    Except as otherwise expressly provided herein, all
terms of an accounting or financial nature shall be construed in accordance with GAAP, as in effect from time to time; provided that, if the Borrower
notifies the Administrative Agent that the Borrower requests an amendment to any provision hereof to eliminate the effect of any change occurring after the date hereof in GAAP or in the application
thereof on the operation of such provision (or if the Administrative Agent notifies the Borrower that the Required Lenders request an amendment to any provision hereof for such purpose),
regardless of whether any such notice is given before or after such change in GAAP or in the application thereof, then such provision shall be interpreted on the basis of GAAP as in effect and applied
immediately before such change shall have become effective until such notice shall have been withdrawn or such provision amended in accordance herewith. 

Third Amended and Restated Credit Agreement

29

 

ARTICLE
II 

COMMITMENTS
AND BORROWING PROCEDURES 

        SECTION 2.1    Loans.    Subject to the terms and conditions set forth herein, each Lender agrees to make
revolving loans ("Loans") to the Borrower from time to time during the Availability Period in an aggregate principal amount that will not result in
(a) such Lender's Exposure exceeding such Lender's Commitment or (b) the total Exposures exceeding the total Commitments. Within the foregoing limits and subject to the terms and
conditions set forth herein, the Borrower may borrow, prepay and reborrow Loans. 

        SECTION 2.2    Loans.

        SECTION 2.2.1    Obligations of Lenders.    Each Loan shall consist of the same type made by the Lenders
ratably in accordance with their respective Commitments. The failure of any Lender to make any Loan required to be made by it shall not relieve any other Lender of its obligations hereunder;  provided
that the Commitments of the Lenders are several and no Lender shall be responsible for any other Lender's failure to make Loans
as required. 

        SECTION 2.2.2    Type of Loans.    Subject to  Section 4.2, each Loan shall be constituted entirely of Base Rate Loans or of LIBO Rate Loans as the Borrower may
request in accordance herewith.
Each Lender at its option may make any LIBO Rate Loans by causing any domestic or foreign branch or Affiliate of such Lender to make such Loan; provided
that any exercise of such option shall not affect the obligation of the Borrower to repay such Loan in accordance with the terms of this Agreement. 

        SECTION 2.2.3    Minimum Amounts; Limitation on Number of Loans.    Each Loan shall be in an aggregate amount
of $5,000,000 or a larger multiple of $1,000,000; provided that a Base Rate Loan may be in an aggregate amount that is equal to the entire unused
balance of the total Commitments or that is required to finance, in an amount not less than $5,000,000, the reimbursement of an LC Disbursement as contemplated by  Section 2.6.5. Loans of more than
one type may be outstanding at the same time; provided that
there shall not at any time be more than a total of ten (10) LIBO Rate Loans outstanding. 

        SECTION 2.2.4    Limitations on Interest Periods.    Notwithstanding any other provision of this Agreement, the
Borrower shall not be entitled to request (or to elect to convert to or continue as a LIBO Rate Loan) any Loan if the Interest Period requested therefor would end after the Commitment
Termination Date. 

        SECTION 2.3    Borrowing Procedure.

        (a)   Each
Borrowing of Loans shall be made on notice, given not later than 12:00 Noon, New York City time, on the third Business Day prior to the date of the
proposed Borrowing (in the case of a Borrowing of Loans to consist of LIBO Rate Loans) and no later than 12:00 Noon, New York City time, on the Business Day of the proposed
Borrowing (in the case of a Borrowing of Loans to consist of Base Rate Loans), by the Borrower to the Administrative Agent, which shall give to each Lender prompt notice thereof by facsimile
transmission. Each such notice of a Borrowing of Loans shall be made in writing, in substantially the form of a Borrowing Request, specifying therein (i) the requested date of such Borrowing
(which shall be a Business Day), (ii) whether such Borrowing is to be a LIBO Rate Loan or a Base Rate Loan, (iii) the requested aggregate amount of such Borrowing, (iv) in the
case of a LIBO Rate Loan, the initial Interest Period therefor and (v) the location and number of the Borrower's Bank Account to which funds are to be disbursed. 

Third Amended and Restated Credit Agreement

30

 

        (b)   Each
Lender shall make each Loan to be made by it hereunder on the proposed date thereof by wire transfer of immediately available funds by 2:00 p.m.,
New York City time, to the account of the Administrative Agent most recently designated by it for such purpose by notice to the Lenders. The Administrative Agent will make such Loans available
to the Borrower by promptly crediting the amounts so received, in like funds, to a Bank Account of the Borrower and designated by the Borrower in the applicable Borrowing Request;  provided that
Borrowings made to finance the reimbursement of an LC Disbursement as provided in  Section 2.6.5 shall be remitted by the Administrative Agent to the Issuing Lender specified in  Section 2.6.5. 

        (c)   If
no election as to the type of a Loan is specified, then the requested Loan shall be a Base Rate Loan. If no Interest Period is specified with respect to any requested
LIBO Rate Loan, then the requested Loan shall be made instead as a Base Rate Loan. 

        SECTION 2.4    Continuation and Conversion Elections.    By delivering a Continuation/Conversion Notice to the
Administrative Agent on or before 12:00 Noon, New York City time, on a Business Day, the Borrower may from time to time irrevocably elect that all, or any portion in an aggregate minimum
amount of $5,000,000 and an integral multiple of $1,000,000 in excess thereof, of any Loans be (a) on not less than three (3) Business Days' notice, converted into, or continued as, LIBO
Rate Loans, or (b) on the same Business Day, be converted into Base Rate Loans. In the absence of delivery of a Continuation/Conversion Notice with respect to any LIBO Rate Loan, such LIBO Rate
Loan shall automatically be continued as a LIBO Rate Loan with an Interest Period of the same duration as the then expiring Interest Period; provided,  however, that (i) each such conversion or continuation shall be pro rated among the applicable outstanding Loans of all Lenders, (ii) a
LIBO Rate Loan may not be converted at any time other than the last day of the Interest Period applicable thereto and (iii) no portion of the outstanding principal amount of any Loans may be
continued as, or be converted into, LIBO Rate Loans when any Default or Event of Default has occurred and is continuing. Each delivery of a Continuation/Conversion Notice shall constitute a
certification and warranty by the Borrower that on the date of delivery of such notice no Default has occurred and is continuing. If prior to the time of such continuation or conversion any matter
certified to by the Borrower by reason of the immediately preceding sentence will not be true and correct at such time if then made, the Borrower will immediately so notify the Administrative Agent.
Except to the extent, if any, that prior to the time of such continuation or conversion the Administrative Agent shall have received written notice to the contrary from the Borrower, such
certification and warranty shall be deemed to be made at the date of such continuation or conversion as if then made. Upon the occurrence and during the continuance of any Event of Default under  Section 8.1.1, each LIBO Rate Loan shall convert automatically to a Base Rate Loan at the end of the Interest Period then in effect for such LIBO
Rate Loan. 

        SECTION 2.5    Funding.    Each Lender may, if it so elects, fulfill its obligation to make, continue or
convert LIBO Rate Loans hereunder by causing one of its foreign branches or Affiliates (or an international banking facility created by such Lender) to make or maintain such LIBO Rate Loan;  provided, however, that such LIBO Rate Loan shall nonetheless be deemed to have been made and to be held
by such Lender, and the obligation of the Borrower to repay such LIBO Rate Loan shall nevertheless be to such Lender for the account of such foreign branch, Affiliate or international banking
facility. In addition, the Borrower hereby consents and agrees that, for purposes of any determination to be made for purposes of Section 4.1,  4.2,
4.3, 4.4, or  4.5, it shall be conclusively assumed that each Lender elected to fund all LIBO Rate Loans by
purchasing deposits in its LIBOR Office's interbank
eurodollar
markets. Notwithstanding the foregoing, such foreign branch or Affiliate shall satisfy the requirements of Section 4.7(e). 

        SECTION 2.6    Letters of Credit.    Subject to the terms and conditions set forth herein, in addition to the
Loans provided for in Section 2.1, the Borrower may request an Issuing Lender to Issue, at any 

Third Amended and Restated Credit Agreement

31

 

time
and from time to time on any Business Day during the period from the Closing Date to the date which is ten (10) Business Days prior to the Commitment Termination Date, Letters of Credit
for its own account in such form as is acceptable to such Issuing Lender in its reasonable determination. Letters of Credit Issued hereunder shall constitute utilization of the Commitments;  provided,
that the Borrower's ability to obtain Letters of Credit shall be fully revolving and accordingly the Borrower may, prior to the Commitment
Termination Date, obtain Letters of Credit to replace Letters of Credit which have expired or which have been drawn and subsequently reimbursed. 

        SECTION 2.6.1    Notice of Issuance, Amendment, Renewal or Extension.    To request the Issuance of a Letter of
Credit (or the amendment, renewal or extension of an outstanding Letter of Credit), the Borrower shall hand deliver or telecopy (or transmit by electronic communication, if arrangements
for doing so have been approved by such Issuing Lender) to an Issuing Lender and the Administrative Agent at least three (3) Business Days (or such shorter time as such Issuing Lender
may agree in a particular instance in its sole discretion) prior to the requested Issuance Date a notice (a "Letter of Credit Application")
requesting the Issuance of a Letter of Credit, or identifying the Letter of Credit to be amended, renewed or extended, and specifying (a) the Issuing Lender for such Letter of Credit,
(b) the Issuance Date (which shall be a Business Day), (c) the date on which such Letter of Credit is to expire (which shall comply with  Section 2.6.3), (d) the amount of such Letter
of Credit, (e) the name and address of the beneficiary thereof, (f) all other
terms and conditions regarding such Letter of Credit and (g) such other information as shall be necessary to prepare, amend, renew or extend such Letter of Credit. If requested by an Issuing
Lender, the Borrower also shall submit a Letter of Credit Application on such Issuing Lender's standard form in connection with any request for a Letter of Credit. In the event of any inconsistency
between the terms and conditions of this Agreement and the terms and conditions of any form of Letter of Credit Application or other agreement submitted by the Borrower to, or entered into by the
Borrower with, an Issuing Lender relating to any Letter of Credit, the terms and conditions of this Agreement shall control. 

        SECTION 2.6.2    Limitations on Amounts.    A Letter of Credit shall be Issued only if (and upon
Issuance of each Letter of Credit the Borrower shall be deemed to represent and warrant that) after giving effect to such Issuance the total Exposure shall not exceed the total Commitments. 

        SECTION 2.6.3    Expiration Date.    Each Letter of Credit shall expire at or prior to the close of business on
the earlier of (a) the date one year (or such longer period as may be agreed upon among the Borrower and the Issuing Lender) after the date of the issuance of such Letter of Credit (or,
in the case of any renewal or extension thereof, one year (or such longer period as may be agreed upon among the
Borrower and the Issuing Lender) after such renewal or extension) and (b) the date that is five (5) Business Days prior to the Commitment Termination Date. 

        SECTION 2.6.4    Participations.    By the Issuance of a Letter of Credit (or an amendment to a Letter
of Credit increasing the amount thereof) by an Issuing Lender, or, in the case of the Letters of Credit set forth on Schedule 2.6.11, by each
Lender's signature on the signature pages hereto, and without any further action on the part of such Issuing Lender or the Lenders, such Issuing Lender hereby grants to each Lender, and each Lender
hereby acquires from such Issuing Lender, a participation in such Letter of Credit equal to such Lender's Percentage of the aggregate amount available to be drawn under such Letter of Credit. Each
Lender acknowledges and agrees that its obligation to acquire participations pursuant to this paragraph in respect of Letters of Credit is absolute and unconditional and shall not be affected by any
circumstance whatsoever, including any amendment, renewal or extension of any Letter of Credit or the occurrence and continuance of a Default or Event of Default or reduction or termination of the
Commitments. 

Third Amended and Restated Credit Agreement

32

 

        In
consideration and in furtherance of the foregoing, each Lender hereby absolutely and unconditionally agrees to pay to the Administrative Agent, for the account of an Issuing Lender,
such Lender's Percentage of each LC Disbursement made by such Issuing Lender promptly upon the request of such Issuing Lender at any time from the time of such LC Disbursement until such
LC Disbursement is reimbursed by the Borrower or at any time after any reimbursement payment is required to be refunded to the Borrower for any reason. Such payment shall be made without any
offset, abatement, withholding or reduction whatsoever. Each such payment shall be made in the same manner as provided in Section 2.3(b) with
respect to Loans made by such Lender (and Section 2.3(b) shall apply, mutatis mutandis, to
the payment obligations of the Lenders), and the Administrative Agent shall promptly pay to the relevant Issuing Lender the amounts so received by it from the Lenders. Promptly following receipt by
the Administrative Agent of any payment from the Borrower pursuant to Section 2.6.5, the Administrative Agent shall distribute such payment to
the relevant Issuing Lender or, to the extent that the Lenders have made payments pursuant to this paragraph to reimburse such Issuing Lender, then to such Lenders and such Issuing Lender as their
interests may appear. Any payment made by a Lender pursuant to this paragraph to reimburse an Issuing Lender for any LC Disbursement shall not constitute a Loan and shall not relieve the
Borrower of its obligation to reimburse such LC Disbursement. 

        SECTION 2.6.5    Reimbursement.    If an Issuing Lender shall make any LC Disbursement in respect of a Letter
of Credit, the Borrower shall reimburse such Issuing Lender in respect of such LC Disbursement by paying to the Administrative Agent an amount equal to such LC Disbursement and any
interest accrued pursuant to Section 2.6.8 not later than 4:00 pm, New York City time, on (a) the Business Day that the
Borrower receives notice of such LC Disbursement if such notice is received by the Borrower on such Business Day prior to 10:00 a.m. New York City time or (b) if  clause (a) above
does not apply, the Business Day immediately following the Business Day that the Borrower receives such notice,  provided that, the Borrower may, subject to the conditions to borrowing set forth herein,
request in accordance with  Section 2.3(a) that an LC Disbursement be financed with a Borrowing (or a portion
thereof) of Loans and, to the extent so financed, the Borrower's obligation to reimburse such LC Disbursement shall be discharged and replaced by the resulting Loan. 

        If
the Borrower fails to make such payment when due, the Administrative Agent shall notify each applicable Lender of the applicable LC Disbursement, the payment then due from the
Borrower in respect thereof and such Lender's Percentage thereof. 

        SECTION 2.6.6    Obligations Absolute.

        (a)   The
Borrower's obligation to reimburse LC Disbursements as provided in Section 2.6.5 shall be absolute,
unconditional and irrevocable, and shall be performed strictly in accordance with the terms of this Agreement under any and all circumstances whatsoever and irrespective of (i) any lack of
validity or enforceability of any Letter of Credit, or any term or provision therein, (ii) any draft or other document presented under a Letter of Credit proving to be forged, fraudulent or
invalid in any respect or any statement therein being untrue or inaccurate in any respect, (iii) payment by an Issuing Lender under a Letter of Credit against presentation of a draft or other
document that does not comply strictly with the terms of such Letter of Credit, and (iv) any other event or circumstance whatsoever, whether or not similar to any of the foregoing, that might,
but for the provisions of this Section 2.6, constitute a legal or equitable discharge of the Borrower's obligations hereunder. 

        (b)   Neither
the Administrative Agent, the Lenders nor the Issuing Lenders, nor any of their respective directors, officers, employees, agents or advisors, shall have any
liability or responsibility by reason of or in connection with the Issuance or transfer of any Letter of Credit by an Issuing 

Third Amended and Restated Credit Agreement

33

 

Lender
or any payment or failure to make any payment thereunder (irrespective of any of the circumstances referred to in the preceding sentence), or any error, omission, interruption, loss or delay in
transmission or delivery of any draft, notice or other communication under or relating to any Letter of Credit (including any document required to make a drawing thereunder), any error in
interpretation of technical terms or any consequence arising from causes beyond the control of an Issuing Lender; provided that the foregoing shall not
be construed to excuse any Issuing Lender from liability to the Borrower to the extent of any direct damages (as opposed to consequential damages, claims in respect of which are hereby waived
by the Borrower to the extent permitted by applicable law) suffered by the Borrower that are caused by such Issuing Lender's gross negligence or willful misconduct when determining whether drafts and
other documents presented under a Letter of Credit comply with the terms thereof. The parties hereto expressly agree that: 

        (i)    each
Issuing Lender may accept documents that appear on their face to be in substantial compliance with the terms of a Letter of Credit without responsibility for
further investigation, regardless of any notice or information to the contrary, and may make payment upon presentation of documents that appear on their face to be in substantial compliance with the
terms of such Letter of Credit; 

        (ii)   each
Issuing Lender shall have the right, in its sole discretion, to decline to accept such documents and to make such payment if such documents are not in strict
compliance with the terms of such Letter of Credit; and 

        (iii)  this
sentence shall establish the standard of care to be exercised by each Issuing Lender when determining whether drafts and other documents presented under a Letter
of Credit comply with the terms thereof (and the parties hereto hereby waive, to the extent permitted by applicable law, any standard of care inconsistent with the foregoing). 

        (c)   Each
Issuing Lender shall act on behalf of the Lenders with respect to any Letters of Credit Issued by it and the documents associated therewith until such time and
except for so long as the Administrative Agent may agree at the request of the Required Lenders to act for such Issuing Lender with respect thereto;  provided, however, that each Issuing Lender shall have all of the benefits and immunities
(i) provided to the Administrative Agent in Article IX with respect to any acts taken or omissions suffered by each Issuing Lender in
connection with Letters of Credit Issued by it or proposed to be Issued by it and the Letter of Credit Documents mutatis mutandis as if set forth in
full therein as if the term "Administrative Agent", as used in Article IX, included each Issuing Lender with respect to such acts or omissions,
and (ii) as additionally provided in this Agreement with respect to each Issuing Lender. 

        SECTION 2.6.7    Disbursement Procedures.    Each Issuing Lender shall, within a reasonable time following its
receipt thereof, examine all documents purporting to represent a demand for payment under a Letter of Credit. Each Issuing Lender shall promptly after such examination notify the Administrative Agent
and the Borrower by telephone (confirmed by telecopy) of such demand for payment and whether such Issuing Lender has made or will make an LC Disbursement thereunder;  provided that any failure to
give or delay in giving such notice shall not relieve the Borrower of its obligation to reimburse such Issuing Lender and
the Lenders with respect to any such LC Disbursement. 

Third Amended and Restated Credit Agreement

34

   
        SECTION 2.6.8    Interim Interest.    If an Issuing Lender shall make any LC Disbursement, then, unless the
Borrower shall reimburse such LC Disbursement in full on the date such LC Disbursement is made, the unpaid amount thereof shall bear interest, for each day from and including the date
such LC Disbursement is made to but excluding the date that the Borrower reimburses such LC Disbursement (in an amount equal to the LC Disbursement if such
LC Disbursement is reimbursed by the Borrower after the date the LC Disbursement is made), at a rate equal to the Alternate Base Rate, in effect from time to time,  plus the Applicable Margin
for Base Rate Loans; provided that, if the Borrower fails to reimburse such
LC Disbursement when due pursuant to Section 2.6.5, then such overdue amount shall bear additional interest (after as well as before
judgment) at a rate equal to 2% per annum. Interest accrued pursuant to this paragraph shall be for account of the Issuing Lender, except that interest accrued on and after the date of payment by any
Lender pursuant to Section 2.6.5 to reimburse such Issuing Lender shall be for account of such Lender to the extent of
such payment. 

        SECTION 2.6.9    Addition and Replacement of Issuing Lenders.    Any Lender may become an Issuing Lender at any
time by written agreement between the Borrower, the Administrative Agent, and such Lender. Any Issuing Lender may be replaced by a Lender at any time by written agreement between the Borrower, the
Administrative Agent, the replaced Issuing Lender and such Lender. The Administrative Agent shall notify the Lenders of any such change of an Issuing Lender. At the time any such change shall become
effective, the Borrower shall pay all unpaid fees accrued for account of the replaced Issuing Lender pursuant to Section 3.3.2. From and after
the effective date of any such change, (a) the Lender becoming an Issuing Lender shall have all the rights and obligations of an Issuing Lender under this Agreement with respect to Letters of
Credit to be Issued thereafter and (b) references herein to the term "Issuing Lender" shall be deemed to refer to such new or to any previous Issuing Lender, or to such new and all previous
Issuing Lenders, as the context shall require. After the replacement of an Issuing Lender hereunder, the replaced Issuing Lender shall remain a party hereto and shall continue to have all the rights
and obligations of an Issuing Lender under this Agreement with respect to Letters of Credit Issued by it prior to such replacement, but shall not be required to Issue additional Letters
of Credit. 

        SECTION 2.6.10    Cash Collateralization.

        (a)   If
an Event of Default shall occur and be continuing and the Borrower receives notice from the (i) Administrative Agent or (ii) the Required Lenders
demanding the deposit of cash collateral pursuant to this paragraph, the Borrower shall immediately deposit into the LC Collateral Account an amount in
cash equal to the LC Exposure requested to be Cash Collateralized in such notice from the Administrative Agent or the Required Lenders as of such date  plus any accrued and unpaid interest thereon;
provided that, in each case, the Borrower's obligation to
Cash Collateralize shall become effective immediately, and such deposit shall become immediately due and payable, without demand or other notice of any kind upon the occurrence of any Event of Default
with respect to the Borrower described in Section 8.1.6. Deposits of cash collateral made pursuant to this  clause (a) to Cash Collateralize
LC Exposure shall be segregated within the LC Collateral Account for application in
accordance with clause (d) below. 

        (b)   If
the Borrower is required to Cash Collateralize Letters of Credit pursuant to Section 3.1.2(d), the Borrower
shall immediately deposit into the LC Collateral Account the amount specified in Section 3.1.2(d). 

        (c)   The
Administrative Agent shall apply deposits made pursuant to clause (b) and any deposits remaining after
application in accordance with clause (d) first to reimburse outstanding LC Disbursements ratably among the Lenders, second to be held in the
LC Collateral Account as collateral for the aggregate undrawn amount of all outstanding Letters of Credit (other than 

Third Amended and Restated Credit Agreement

35

 

Letters
of Credit Cash Collateralized pursuant to clause (d) below) at such time under this Agreement and thereafter for the payment of the "Secured Obligations" under and as defined in the
Collateral Trust Agreement, and, for these purposes, the Borrower hereby grants a security interest to the Administrative Agent for the benefit of the Lenders in the LC Collateral Account and in any
"financial assets" (as defined in Section 8-102(a)(9) of the UCC) or other property held therein. 

        (d)   The
Administrative Agent shall apply deposits made pursuant to clause (a) to Cash Collateralize
LC Exposure first to reimburse outstanding LC Disbursements among the Lenders, second to be held in the LC Collateral Account as collateral for the aggregate undrawn amount of all
outstanding Letters of Credit at such time. Any deposits made pursuant to clause (a) and remaining after application in accordance with
this clause (d) shall be applied pursuant to clause (c) above. 

        (e)   At
any time no Default or Event of Default has occurred and is continuing, the Borrower may request, upon five (5) Business Days' prior written notice to the
Administrative Agent the refund of cash collateral deposited in the LC Collateral Account pursuant to clause (b) in an amount equal to the
lesser of (i) the amount of cash collateral deposited pursuant to clause (b) and (ii) an amount equal to the excess of outstanding
Commitments over the Exposure of all Lenders at such time. 

        SECTION 2.6.11    Existing Letters of Credit.    The Borrower hereby (a) designates the letter of credit
listed on Schedule 2.6.11 (the "Existing Letter of Credit") as a Letter of Credit issued
by CNAI as the Issuing Lender and (b) accepts, acknowledges and assumes all obligations with respect to the Existing Letter of Credit pursuant to the terms and conditions of
this Agreement. 

ARTICLE
III 

REPAYMENTS,
PREPAYMENTS, INTEREST AND FEES 

        SECTION 3.1    Repayments, Amortization and Prepayments.    The Loans shall mature, and the Borrower hereby
unconditionally promises to pay in full the unpaid principal amount and all amounts outstanding and unpaid in respect of the Loans to the Administrative Agent for the account of each Lender, on the
Commitment Termination Date. 

        SECTION 3.1.1    Optional Prepayments and Commitment Reductions.    At any time, and from time to time, the
Borrower may, on any Business Day, make a voluntary prepayment or permanent commitment reduction, in whole or in part, of the outstanding principal amount of the Loans (in the Borrower's
discretion) or the Commitments thereunder; provided, however, that: 

        (a)   any
such prepayment or commitment reduction shall be applied pro rata among the Lenders in accordance with the
respective unpaid principal amounts of the Loans and Commitments thereunder held by them; provided, that the Commitments shall not be reduced to an
amount that is less than the aggregate Exposure then in effect; 

        (b)   any
such prepayment or commitment reduction made shall be applied pro rata among Loans and Commitments of the same
type and, if applicable, having the same Interest Period; 

        (c)   any
such prepayment of any LIBO Rate Loan made on any day other than the last day of the Interest Period for such Loan shall be subject to the provisions of  Section 4.5; 

        (d)   any
such prepayment of LIBO Rate Loans shall require at least two (2) Business Days' prior written notice to the Administrative Agent and any such prepayment of
Base Rate Loans may be made on same day's written notice to the Administrative Agent; and 

Third Amended and Restated Credit Agreement

36

 

        (e)   any
such partial prepayment of Loans shall be in an aggregate minimum amount of $10,000,000 and an integral multiple of $1,000,000 in excess thereof. 

        SECTION 3.1.2    Acceleration; Penalty.

        (a)   The
Borrower shall immediately upon any acceleration of any Loans pursuant to Section 8.2 or  Section 8.3, repay all Loans, unless, pursuant to
Section 8.3, only a portion of all Loans
is so accelerated (in which event the Borrower shall repay the portion of the Loans so accelerated). 

        (b)   Each
prepayment of Loans made pursuant to Section 3.1 shall be accompanied by accrued interest to the date of such
prepayment on the amount prepaid, but shall be without premium or penalty, except as may be required by Section 4.5. 

        SECTION 3.2    Interest Provisions.    Interest on the outstanding principal amount of Loans shall accrue and
be payable in accordance with this Section 3.2. 

        SECTION 3.2.1    Rates.

        (a)   Pursuant
to an appropriately delivered Borrowing Request or Continuation/ Conversion Notice, the Borrower may elect that the Loans or a portion of the Loans pursuant to  Section 2.3 accrue interest at a rate
per annum: 

        (i)    on
that portion maintained from time to time as a Base Rate Loan, equal to the sum of the Alternate Base Rate from time to time in effect  plus the Applicable Margin for Base Rate Loans from time to time in
effect; and 

        (ii)   on
that portion maintained as a LIBO Rate Loan, during each Interest Period applicable thereto, equal to the sum of the Adjusted LIBO Rate for such Interest Period  plus the Applicable Margin for LIBO Rate
Loans from time to time in effect. 

        (b)   All
LIBO Rate Loans shall bear interest from and including the first day of the applicable Interest Period to (but not including) the last day of such Interest
Period at the interest rate determined as applicable to such LIBO Rate Loan. 

        SECTION 3.2.2    Default Rates.    Upon the occurrence and during the continuance of any Event of Default, the
Borrower shall pay, but only to the extent permitted by law, in addition to the applicable Alternate Base Rate or Adjusted LIBO Rate plus the Applicable
Margin on each such Loan, then payable on the Loans, additional interest (after as well as before judgment) on the Loans at 2% per annum until such Event of Default is cured. 

        SECTION 3.2.3    Payment Dates.    Interest accrued on each Loan shall be payable, without duplication: 

        (a)   on
the Commitment Termination Date; 

        (b)   on
the date of any payment or prepayment, in whole or in part, of principal outstanding on such Loan and upon the termination of the Commitments,  provided, that upon a payment or prepayment in part, only
the interest accrued on such portion shall be payable; 

        (c)   with
respect to Base Rate Loans, on each Quarterly Payment Date occurring after the Closing Date; 

        (d)   with
respect to LIBO Rate Loans, the last day of each applicable Interest Period (and, if such Interest Period shall exceed three months, on the day three months after
such Loan is made or continued); and 

Third Amended and Restated Credit Agreement

37

 

        (e)   on
that portion of any Loans which is accelerated pursuant to Section 8.2 or  Section 8.3, immediately upon such acceleration. 

Interest
accrued on Loans or other monetary Obligations arising under any Loan Document after the date such amount is due and payable (whether on the related maturity date, upon acceleration or
otherwise) shall be payable upon demand. 

        SECTION 3.2.4    Interest Rate Determination.    The Administrative Agent shall determine the interest rate
applicable to Loans and shall give prompt notice to the Borrower and the Lenders of such determination, and its determination thereof shall be conclusive in the absence of manifest error. 

        SECTION 3.3    Fees.

        SECTION 3.3.1    Commitment Fee.    The Borrower agrees to pay to the Administrative Agent for the ratable
account of each Lender a commitment fee which shall accrue on the average daily unused amount of the Commitment of such Lender during the period from and including the Closing Date to but excluding
the earlier of the date such Commitment terminates and the Commitment Termination Date at the rate per annum for the Loans based on the Debt Rating for such day determined as provided in the Pricing
Grid. Accrued commitment fees shall be payable on each Quarterly Payment Date and on the earlier of the date the Commitments terminate and the Commitment Termination Date commencing on the first such
date to occur after the date hereof. All commitment fees shall be computed on the basis of a year of 360 days and shall be payable for the actual number of days elapsed (including the first day
but excluding the last day). For purposes of computing commitment fees, the Commitment of a Lender shall be deemed to be used to the extent of the outstanding Loans and LC Exposure of
such Lender. 

        SECTION 3.3.2    Letter of Credit Fees.    The Borrower agrees to pay: 

        (a)   to
the Administrative Agent for the account of each Lender a participation fee (a "Participation Fee") with
respect to its participations in Letters of Credit, which shall accrue at a rate per annum based on the Borrower's Debt Rating for such day determined as provided in the Pricing Grid on the average
daily amount of such Lender's LC Exposure (excluding any portion thereof attributable to unreimbursed LC Disbursements) during the period from and including the Closing Date to but
excluding the later of the date on which such Lender's Commitment terminates and the date on which such Lender ceases to have any LC Exposure; and 

        (b)   to
each Issuing Lender a fronting fee, which shall accrue at the rate of 0.10% per annum (or such lesser amount as shall have been agreed from time to time
between the Borrower and an Issuing Lender) on the average daily amount of the LC Exposure of each such Issuing Lender (excluding any portion thereof attributable to unreimbursed
LC Disbursements), during the period from and including the Closing Date to but excluding the later of the date of termination of the Commitments and the date on which there ceases to be any
LC Exposure as well as each such Issuing Lender's standard fees with respect to the Issuance of any Letter of Credit or processing of drawings thereunder. 

        Participation
Fees and fronting fees accrued through and including each Quarterly Payment Date shall be payable on such Quarterly Payment Date, commencing on the first such date to occur
after the Closing Date; provided that all such fees with respect to LC Exposure shall be payable on the date on which the Commitments terminate
and any such fees accruing after the date on which the Commitments terminate shall be payable on demand. Any other fees payable to an Issuing Lender pursuant to this paragraph shall be payable within
ten (10) days after demand. All Participation Fees and fronting fees shall be computed on the basis of a year of 360 days and shall be payable for the actual number of days elapsed
(including the first day but excluding the last day). 

Third Amended and Restated Credit Agreement

38

 

        SECTION 3.3.3    Other Fees.    The Borrower agrees to pay to the Administrative Agent, for (a) its own
account, (b) the account of JPMCB and (c) the account of the Issuing Lenders, the respective fees as agreed to in the Fee Letters. 

        SECTION 3.3.4    Payment of Fees.    All fees payable hereunder shall be paid on the dates due, in immediately
available funds, to the Administrative Agent (or to the Issuing Lenders, in the case of fees payable to it) for distribution, in the case of facility fees and Participation Fees, to the Lenders
entitled thereto. Fees paid shall not be refundable under any circumstances. 

        SECTION 3.4    Extension of Commitment Termination Date.

        (a)   The
Borrower may, by notice to the Administrative Agent (which shall promptly notify the Lenders) not more than 90 days and not less than 30 days prior to
each anniversary of the Closing Date (such anniversary date, an "Extension Date"), request (each, an "Extension
Request") that the Lenders extend the Commitment Termination Date then in effect (the "Existing Commitment Termination
Date") for an additional one year, provided that no more than two Extension Requests shall be permitted hereunder. Each Lender,
acting in its sole discretion, shall, by notice to the Borrower and the Administrative Agent, given not later than the 20th day (or such later day as shall be acceptable by
the Borrower) following the date of the Borrower's notice, advise the Borrower whether or not such Lender agrees to such Extension Request; provided
that any Lender that does not so advise the Borrower shall be deemed to have denied such Extension Request. The election of any Lender to agree to such extension shall not obligate any other Lender to
so agree. 

        (b)   The
Borrower shall have the right at any time on or prior to the relevant Extension Date to replace any non-extending Lender with, and otherwise add to this
Agreement, one or more other lenders (which may include any Lender) (each an "Additional Commitment Lender") in each case with the consent of the
Administrative Agent (such consent not to be unreasonably withheld) and each Issuing Bank. Each Additional Commitment Lender which has been so approved shall enter into an agreement in form and
substance satisfactory to the Borrower and the Administrative Agent pursuant to which such Additional Commitment Lender shall, effective as of the Extension Date, undertake a
Commitment and (if not already a Lender under this Agreement) become a Lender hereunder (and, if such Additional Commitment Lender is already a Lender, agree to increase its Commitment
hereunder) in the agreed amount as long as each Non-extending Lender being replaced is paid in full. 

        (c)   If
(and only if) the total Commitments of the Lenders that have agreed in connection with any Extension Request to extend the Existing Commitment Termination Date
and the additional Commitments of the Additional Commitment Lenders shall be at least 50% of the total Commitments in effect immediately prior to the Extension Date, then, effective as of the
Extension Date, the Commitment Termination Date, with respect to the Commitment of each Lender that has agreed to so extend its Commitment and of each Additional Commitment Lender shall be extended to
the date falling one year after the Existing Commitment Termination Date (or, if such date is not a Business Day such Commitment Termination Date as so extended shall be the next preceding Business
Day) and each Additional Commitment Lender shall thereupon become a "Lender" for all purposes of this Agreement. 

        Notwithstanding
the foregoing, the extension of the Existing Commitment Termination Date shall not be effective with respect to any Lender unless as of the relevant Extension Date
(i) no Default or Event of Default shall have occurred and be continuing and (ii) each representation and warranty set forth in Article VI shall be true and correct as if made on
and as of such date, unless such representation or warranty relates solely to another time, in which event such representation or 

Third Amended and Restated Credit Agreement

39

 

warranty
shall be true and correct as of such other time (and the Administrative Agent shall have received a certification to such effect from an Authorized Officer of the Borrower, together
with such evidence and other related documents as the Administrative Agent may reasonably request with respect to the Borrower's authorization of the extension and their respective obligations
hereunder). 

        Notwithstanding
anything herein to the contrary, with respect to the Commitment of any Lender that has not approved any Extension Request and has not been replaced as a Lender hereunder
pursuant to Section 3.4(b), the Commitment Termination Date shall remain unchanged. 

ARTICLE
IV 

CERTAIN
LIBO RATE AND OTHER PROVISIONS 

        SECTION 4.1    LIBO Rate Lending Unlawful.    If any Lender shall reasonably determine (which determination
shall, upon notice thereof to the Borrower and the Administrative Agent, be conclusive
and binding on the Borrower absent manifest error) that the introduction of or any change in or in the interpretation of any law, rule or regulation makes it unlawful, or any central bank or other
Governmental Authority or comparable agency asserts that it is unlawful, for such Lender to make, continue or maintain any Loan as, or to convert any Loan into, a LIBO Rate Loan, the obligations of
such Lender to make, continue, maintain or convert any such Loans shall, upon such determination, forthwith be suspended until such Lender shall notify the Administrative Agent that the circumstances
causing such suspension no longer exist, and all LIBO Rate Loans of such Lender shall automatically convert into Base Rate Loans at the end of the then current Interest Periods with respect thereto or
sooner, if required by such law or assertion. 

        SECTION 4.2    Inability to Determine Rates.    If the Administrative Agent shall have determined that by
reason of circumstances affecting the Administrative Agent's relevant market, adequate means do not exist for ascertaining the interest rate applicable hereunder to LIBO Rate Loans, then, upon notice
from the Administrative Agent to the Borrower and the Lenders, the obligations of all Lenders under Section 2.3 and  Section 2.4 to make or
continue any Loans as, or to convert any Loans into, LIBO Rate Loans shall forthwith be suspended until the
Administrative Agent shall notify the Borrower and the Lenders that the circumstances causing such suspension no longer exist. 

        SECTION 4.3    Increased LIBO Rate Loan Costs.    If after the date hereof, the adoption of any applicable law,
rule or regulation, or any change therein, or any change in the interpretation or administration thereof by any Governmental Authority, central bank or comparable agency charged with the
interpretation or administration thereof, or compliance by any Lender (or its LIBOR Office) with any request or directive (whether or not having the force of law) of any such authority, central
bank or comparable agency shall increase the cost to such Lender of, or result in any reduction in the amount of any sum receivable by such Lender in respect of, making, continuing or maintaining
(or of its obligation to make, continue or maintain) any Loans as, or of converting (or of its obligation to convert) any Loans into, LIBO Rate Loans, then the Borrower agrees to pay to
the Administrative Agent for the account of such Lender the amount of any such increase or reduction. Such Lender shall promptly notify the Administrative Agent and the Borrower in writing of the
occurrence of any such event, such notice to state, in reasonable detail, the reasons therefor and the additional amount required to compensate fully such Lender for such increased cost or reduced
amount. Such additional amounts shall be payable by the Borrower directly to such Lender within ten (10) Business Days of its receipt of such notice, and such notice shall be binding on the
Borrower absent clear and convincing evidence to the contrary. 

        SECTION 4.4    Obligation to Mitigate.    Each Lender agrees that as promptly as practicable after it becomes
aware of the occurrence of an event that would entitle it to give notice pursuant to 

Third Amended and Restated Credit Agreement

40

 

 Section 4.1, 4.3 or 4.6 or to receive additional amounts pursuant
to Section 4.7, and in any event if so requested by the Borrower, such Lender shall use reasonable efforts to make, fund or maintain its affected
Loans through another lending office if as a result thereof the increased costs would be avoided or materially reduced or the illegality would thereby cease to exist and if, in the reasonable opinion
of such Lender, the making, funding or maintaining of such Loans through such other lending office would not in any material respect be disadvantageous to such Lender, contrary to such Lender's normal
banking practices or violate any applicable law or regulation. No change by a Lender in its Domestic Office or LIBOR Office made for such Lender's convenience shall result in any increased cost to the
Borrower. The Borrower shall not be obligated to compensate any Lender for the amount of any additional amount pursuant to Section 4.1,  4.3
or 4.6 accruing prior to the date which is ninety (90) days before the date on which
such Lender first notifies the Borrower that it intends to claim such compensation; it being understood that the calculation of the actual amounts may not be possible within such period and that such
Lender may provide such calculation as soon as reasonably practicable thereafter without affecting or limiting the Borrower's payment obligation thereunder. If any Lender demands compensation pursuant
to Section 4.1, 4.3 or 4.6 with respect to
any LIBO Rate Loan, the Borrower may, at any time upon at least one (1) Business Day's prior notice to such Lender through the Administrative Agent, elect to convert such Loan into a Base Rate
Loan. Thereafter, unless and until such Lender notifies the Borrower that the circumstances giving rise to such notice no longer apply, all such LIBO Rate Loans by such Lender shall bear interest as
Base Rate Loans, notwithstanding any prior election by the Borrower to the contrary. If such Lender notifies the Borrower that the circumstances giving rise to such notice no longer apply, the
Borrower may elect that the principal amount of each such Loan again bear interest as LIBO Rate Loans in accordance with this Agreement, on the first day of the next succeeding Interest Period
applicable to the related LIBO Rate Loans of other Lenders. Additionally, the Borrower may, at its option, upon at least five (5) Business Days' prior notice to such Lender, elect to prepay in
full, without premium or penalty, such Lender's affected LIBO Rate Loans. If the Borrower elects to prepay any Loans pursuant to this  Section 4.4, the Borrower shall pay within ten (10)
 Business Days after written demand any additional increased costs of such Lender
accruing for the period prior to such date of prepayment. If such conversion or prepayment is made on a day other than the last day of the current Interest Period for such affected LIBO Rate Loans,
such Lender shall be entitled to make a request for, and the Borrower shall pay, compensation under Section 4.5. 

        SECTION 4.5    Funding Losses.    In the event any Lender shall incur any loss or expense (including any loss
or expense incurred by reason of the liquidation or redeployment of deposits or other funds acquired by such Lender to make, continue or maintain any portion of the principal amount of any Loan as, or
to convert any portion of the principal amount of any Loan into, a LIBO Rate Loan) as a result of: 

        (a)   any
conversion or repayment or prepayment of the principal amount of any LIBO Rate Loans on a date other than the scheduled last day of the Interest Period applicable
thereto, whether pursuant to Section 3.1 or otherwise; or 

        (b)   any
Loans not being continued as, or converted into, LIBO Rate Loans in accordance with the Continuation/Conversion Notice therefor; 

then,
upon the written notice of such Lender to the Borrower (with a copy to the Administrative Agent), the Borrower shall, within ten (10) Business Days of its receipt thereof, pay to the
Administrative Agent for the account of such Lender such amount as will (in the reasonable determination of such Lender) reimburse such Lender for such loss or expense. Such written notice
(which shall include calculations in reasonable detail) shall be binding on the Borrower absent manifest error. 

Third Amended and Restated Credit Agreement

41

   
        SECTION 4.6    Increased Capital Costs.    If after the date hereof any change in, or the introduction,
adoption, effectiveness, interpretation, reinterpretation or phase-in of, any applicable law or regulation, directive, guideline, decision or request (whether or not having the force of
law) of any court, central bank, regulator or other Governmental Authority affects the amount of capital required to be maintained by any Lender or any Issuing Lender, and such Lender or such Issuing
Lender reasonably determines that the rate of return on its capital as a consequence of its Loans or participating in issuing or maintaining any Letters of Credit as the case may be, made by such
Lender or such Issuing Lender is reduced in a material amount to a level below that which such Lender or such Issuing Lender could have achieved but for the occurrence of any such circumstance, then,
in any such case upon notice from time to time by such Lender or such Issuing Lender to the Borrower, the Borrower shall pay within ten (10) Business Days after such demand directly to such
Lender or such Issuing Lender additional amounts sufficient to compensate such Lender or such Issuing Lender for such reduction in rate of return. A statement of such Lender or such Issuing Lender as
to any such additional amount or amounts (including calculations thereof in reasonable detail) shall be binding on the Borrower absent manifest error. 

        SECTION 4.7    Taxes.

        (a)   Payments Free of Taxes.    Any and all payments by or on account of any obligation of the Borrower hereunder or
under any other Loan Document shall be made free and clear of and without deduction for any Indemnified Taxes or Other Taxes; provided that if the
Borrower shall be required to deduct any Indemnified Taxes or Other Taxes from such payments, then (i) the sum payable shall be increased as necessary so that after making all required
deductions (including deductions applicable to additional sums payable under this Section) the Administrative Agent, Issuing Lender or Lender as the
case may be, receives an amount equal to the sum it would have received had no such deductions been made, (ii) the Borrower shall make such deductions and (iii) the Borrower shall pay
the full amount deducted to the relevant Governmental Authority in accordance with applicable law. 

        (b)   Payment of Other Taxes by the Borrower.    In addition, the Borrower shall pay any Other Taxes to the relevant
Governmental Authority in accordance with applicable law. 

        (c)   Indemnification by the Borrower.    The Borrower shall indemnify the Administrative Agent, each Issuing Lender
and each Lender, within ten (10) days after written demand therefor, for the full amount of any Indemnified Taxes or Other Taxes (including Indemnified Taxes or Other Taxes imposed or asserted
on or attributable to amounts payable under this Section) paid by the Administrative Agent, such Issuing Lender or such Lender, as the case may be, and
any penalties, interest and reasonable expenses arising therefrom or with respect thereto, whether or not such Indemnified Taxes or Other Taxes were correctly or legally imposed or asserted by the
relevant Governmental Authority. A certificate as to the amount of such payment or liability delivered to the Borrower by a Lender, by an Issuing Lender or by the Administrative Agent on its own
behalf or on behalf of a Lender or an Issuing Lender, shall be conclusive absent manifest error. 

        (d)   Evidence of Payments.    As soon as practicable after any payment of Indemnified Taxes or Other Taxes by the
Borrower to a Governmental Authority, the Borrower shall deliver to the Administrative Agent the original or a certified copy of a receipt issued by such Governmental Authority evidencing such
payment, a copy of the return reporting such payment or other evidence of such payment reasonably satisfactory to the Administrative Agent. 

        (e)   Foreign Lenders.    Each Lender that is not a United States Person
(a "Non-U.S. Lender"), to the extent that it is legally able to do so, shall deliver to the Borrower and the Administrative
Agent two copies of U.S. Internal Revenue Service Form W-8ECI, Form W-8BEN or 

Third Amended and Restated Credit Agreement

42

 

Form W-8IMY
(with supporting documentation), or any subsequent versions thereof or successors thereto properly completed and duly executed by such Non-U.S. Lender
claiming complete exemption from, or a reduced rate of, U.S. federal withholding tax on all payments of interest by the Borrower under the Loan Documents. Such forms shall be delivered by each
Non-U.S. Lender on or before the date it becomes a party to this Agreement. In addition, each Non-U.S. Lender shall deliver such forms promptly upon the
obsolescence or invalidity of any form previously delivered by such Non-U.S. Lender. Each Non-U.S. Lender shall promptly notify the Borrower at any time it
determines that it is no longer in a position to provide any previously delivered certificate to the Borrower (or any other form of certification adopted by the U.S. taxing authorities
for such purpose). 

        SECTION 4.8    Payments, Computations.    Unless otherwise expressly provided, all payments by the Borrower
pursuant to any Loan Document shall be made by the Borrower to the Administrative Agent for the pro rata account of the Lenders entitled to
receive such payment. All such payments required to be made to the Administrative Agent shall be made, without setoff, deduction or counterclaim, not later than 12:00 Noon, New York City
time, on the date due, in immediately available funds, to such account as the Administrative Agent shall specify from time to time by notice to the Borrower;  provided that such payment shall be deemed
made timely if made by wire transfer and by such time as an Authorized Representative has advised the
Administrative Agent of the applicable Federal Reserve System wire transfer confirmation number. Funds received after that time shall be deemed to have been received by the Administrative Agent on the
next succeeding Business Day. The Administrative Agent shall promptly remit in immediately available funds to each Lender its share, if any, of such
payments received by the Administrative Agent for the account of such Lender. All interest and fees shall be computed on the basis of the actual number of days (including the first day but excluding
the last day) occurring during the period for which such interest or fee is payable over a year comprised of 360 days (or, in the case of interest on a Base Rate Loan, 365 days or, if
appropriate, 366 days). Whenever any payment to be made shall otherwise be due on a day which is not a Business Day, such payment shall (except as otherwise required by  clause (a) of the
definition of the term "Interest Period" with respect to LIBO Rate Loans) be
made on the next succeeding Business Day and such extension of time shall be included in computing interest and fees, if any, in connection with such payment. 

        SECTION 4.9    Sharing of Payments.    If any Lender shall obtain any payment or other recovery (whether
voluntary, involuntary, by application of setoff or otherwise) on account of any Loan or LC Disbursement (other than pursuant to the terms of  Sections 4.3, 4.4, 4.5,  4.6, 4.7 and 4.11) in excess of its  pro rata share of payments then or therewith obtained by all Lenders holding Loans of such type, such Lender shall purchase from the other
Lenders such participations in Loans and LC Disbursements made by them as shall be necessary to cause such purchasing Lender to share the excess payment or other recovery ratably with each of
them; provided, however, that if all or any portion of the excess payment or other recovery is
thereafter recovered from such purchasing Lender, the purchase shall be rescinded and each Lender which has sold a participation in any Loan or LC Disbursement to the purchasing Lender shall
repay to the purchasing Lender the purchase price to the ratable extent of such recovery together with an amount equal to such selling Lender's ratable share (according to the proportion of
(a) the amount of such selling Lender's required repayment to the purchasing Lender to (b) the total amount so recovered from the purchasing Lender) of any interest or other amount paid
or payable by the purchasing Lender in respect of the total amount so recovered. The Borrower agrees that any Lender so purchasing a participation from another Lender pursuant to this  Section 4.9
may, to the fullest extent permitted by law, exercise all its rights of payment (including pursuant to  Section 4.10) with respect to such participation as fully as if such Lender were the
direct creditor of the Borrower in the amount of such
participation. 

Third Amended and Restated Credit Agreement

43

 

        If
under any applicable bankruptcy, insolvency or other similar law, any Lender receives a secured claim in lieu of a setoff to which this  Section 4.9 applies, such Lender shall, to the extent
practicable, exercise its rights in respect of such secured claim in a manner consistent
with the rights of the Lenders entitled under this Section 4.9 to share in the benefits of any recovery on such secured claim. 

        SECTION 4.10    Setoff.    Each of the Lenders and the Issuing Lenders shall, upon the occurrence of any Event
of Default described in clause (a) or (b) of  Section 8.1.6 and, upon the occurrence of any
Default described in clauses (c)
and (d) of Section 8.1.6 or, with the consent of the Required Lenders, upon the occurrence
and continuance beyond the expiration of the applicable grace period, if any, of any other Event of Default, have the right to appropriate and apply to the payment of the Obligations owing to it
(whether or not then due) under the Loan Documents; provided, however, that any such appropriation and
application shall be subject to the provisions of Section 4.9. 

        Each
Lender agrees promptly to notify the Borrower and the Administrative Agent after any such setoff and application made by such Lender;  provided, however,
that the failure to give such notice shall not affect the validity of such setoff and
application. 

        The
rights of each Lender under this Section 4.10 are in addition to other rights and remedies (including other rights of setoff
under applicable law or otherwise) which such Lender may have. 

        SECTION 4.11    Replacement of Lender.    The Borrower shall be permitted to replace (with one or more
replacement Lenders) any Lender: (a) that does not consent to a waiver, amendment or modification pursuant to Section 10.1 that requires a
vote of holders of 100% of the Lenders (provided, that, such replacement Lender consents to such waiver, amendment or modification) or (b) which
requests reimbursement for, or is otherwise entitled to, amounts owing pursuant to Section 4.1,  4.3, 4.6 or 4.7;  provided that (i) such replacement does not conflict with any law, treaty, rule or regulation or determination of an arbitrator
or a court or
other Governmental Authority, in each case applicable to the Borrower or such Lender or to which the Borrower or such Lender or any of their respective property is subject, (ii) no Default or
Event of Default shall have occurred and be continuing at the time of such replacement (other than, in the case of a replacement predicated upon  clause (a) above, the Default or Event of Default
that is the subject of the vote referred to in  clause (a) above), (iii) the replacement bank or institution shall purchase, at par all Loans and other amounts owing to such replaced
Lender prior to the date of replacement, (iv) the Borrower shall be liable to such replaced Lender under Section 4.5 if any LIBO Rate Loan
owing to such replaced Lender shall be prepaid (or purchased) other than on the last day of the Interest Period relating thereto, (v) the replacement Lender shall be reasonably
satisfactory to the Administrative Agent and the Issuing Lenders, (vi) the replaced Lender shall be obligated to make such replacement in accordance with the provisions of  Section 10.11.1
(provided that the Borrower or replacement Lender shall be obligated to pay the
registration and processing fee), (vii) until such time as such replacement shall be consummated, the Borrower shall pay all additional amounts (if any) required pursuant to  Section 4.1,
4.3, 4.6
or 4.7, as the case may be, (viii) any such replacement shall not be deemed to be a waiver of any rights which the Borrower, the
Administrative Agent, any Issuing Lender or any other Lender shall have against the replaced Lender, (ix) if such replacement bank or institution is not already a Lender, the Borrower shall pay
to the Administrative Agent an administrative fee of $3,500 and (x) in the case of a replacement predicated upon clause (a) above,
for the related vote referred to in clause (a) above, no more Lenders than Lenders holding 20% or more of the aggregate outstanding
principal amount of the Loans shall be replaced by the Borrower (provided that the Borrower may replace a single Lender holding greater than 20% of the
aggregate outstanding principal amount of the Loans). 

Third Amended and Restated Credit Agreement

44

 

ARTICLE
V 

CONDITIONS
TO LOANS 

        SECTION 5.1    Conditions to Effectiveness.    This Agreement shall become effective, as between all parties
hereto, upon the satisfaction of each of the conditions precedent set forth in this Section 5.1. 

        SECTION 5.1.1    Delivery of Loan Documents.    The Administrative Agent shall have received: 

        (a)   this
Agreement, duly executed and delivered by an Authorized Representative of the Borrower, with a counterpart for each Lender party hereto on the Closing Date; 

        (b)   the
Communications Agreement, duly executed and delivered by an Authorized Representative of the Borrower; 

        (c)   a
copy, certified by an Authorized Representative of the Borrower, of each of the following documents, each such document shall have been duly executed and delivered by
each of the intended parties thereto: 

        (i)    the
Borrower Security Agreement; 

        (ii)   each
Pledge Agreement; 

        (iii)  the
EMMT Security Agreement; 

        (iv)  the
Collateral Trust Agreement; and 

        (v)   the
Mortgaged Facility Mortgages. 

        SECTION 5.1.2    Officer's Certificates.    The Administrative Agent shall have received: 

        (a)   a
certificate from an Authorized Representative of the Borrower (i) certifying that all representations and warranties made by it in this Agreement and the
Borrower Security Agreement are true and correct in all material respects on and as of the Closing Date (except with respect to representations and warranties made as of a prior specific date), before
and after giving effect to the Borrowing on the
date hereof and to the application of the proceeds therefrom, (ii) certifying that no Default or Event of Default, has occurred and is continuing, or would result from such Borrowing and
(iii) calculating the Debt to Capitalization Ratio as of December 31, 2006 (after giving effect to such Borrowing and the application of the proceeds thereof as if they had occurred on
such date) for the immediately preceding four full Fiscal Quarters; and 

        (b)   a
certificate of an Authorized Representative of (i) EMMT certifying that all representations and warranties made by it in the EMMT Security Agreement are true
and correct in all material respects on and as of the Closing Date (except with respect to representations and warranties made as of a prior specific date), before and after giving effect to such
Borrowing and to the application of the proceeds therefrom and (ii) each Midwest Related Party certifying that all representations and warranties made by it in the Pledge Agreement to which it
is a party are true and correct in all material respects on and as of the Closing Date (except with respect to representations and warranties made as of a prior specific date), before and after giving
effect to such Borrowing and to the application of the proceeds therefrom. 

Third Amended and Restated Credit Agreement

45

 

        SECTION 5.1.3    Resolutions.    The Administrative Agent shall have received from the Borrower, EMMT and each
of the Midwest Related Parties a certificate dated the Closing Date of its Secretary, Assistant Secretary or Authorized Representative as to: 

        (a)   resolutions
of its Board of Directors or managing members, as the case may be, then in full force and effect authorizing the execution, delivery and performance of each
Loan Document to be executed by it on the Closing Date; 

        (b)   the
incumbency and signatures of those of its officers and representatives authorized to act with respect to each Loan Document executed by it on the Closing
Date; and 

        (c)   such
Person's Organic Documents. 

        The
Administrative Agent and each Lender may conclusively rely upon such certificate until it shall have received a further certificate of the Secretary, Assistant Secretary or other
Authorized Representative of such Person canceling or amending such prior certificate. 

        SECTION 5.1.4    Opinions of Counsel.    The Administrative Agent shall have received opinions, dated the
Closing Date and addressed to the Administrative Agent and the Lenders, from counsel to the
Borrower reasonably acceptable to the Administrative Agent, substantially in the forms of Exhibit D-1 through  Exhibit D-6 hereto.

        SECTION 5.1.5    Closing Fees, Expenses.    The Administrative Agent shall have received (a) for the
account of the Existing Lenders and the Issuing Lender with respect to the Existing Credit Agreement, in each case, all accrued fees through the Closing Date and all fees otherwise payable to the
Existing Lenders and such Issuing Lender pursuant to Section 3.3 of the Existing Credit Agreement, (b) for the account of the Existing Lenders, all amounts payable to the Existing
Lenders through the Closing Date pursuant to Section 4.5 of the Existing Credit Agreement (after giving effect to the termination of the Interest Periods (as defined in the Existing
Credit Agreement) applicable to the Revolver Loans under (and as defined in) the Existing Credit Agreement on the Closing Date, and the Borrower hereby acknowledges such termination of such
Interest Periods), and (c) for its own account, or for the account of each Lender and JPMCB, as the case may be, all fees due and payable pursuant to  Sections 3.3 and 10.3, and all other costs and expenses for which invoices have
been presented. 

        SECTION 5.1.6    Financial Statements.    The Administrative Agent shall have received: 

        (a)   an
audited consolidated balance sheet of the Borrower and its Subsidiaries at December 31, 2006; and 

        (b)   an
audited consolidated income statement of the Borrower and its Subsidiaries for the year ended December 31, 2006. 

        SECTION 5.1.7    Existing Indebtedness.    The Administrative Agent shall have received evidence satisfactory
to it that upon the Closing Date (a) the Revolver Loans and the Term Loans (each as defined in the Existing Credit Agreement) and all other amounts due and payable under the Existing Credit
Agreement shall have been paid in full and all letters of credit under (and as defined in) the Existing Credit Agreement shall have been terminated or shall have been designated and assumed in
accordance with Section 2.6.11, (b) the holders of the Notes shall have released all of the Collateral securing such Notes and
(c) all Parity Lien Obligations (as defined in the Collateral Trust Agreement), if any, shall have been paid in full and the holders thereof shall have released all of the Collateral
securing such Parity Lien Obligations (as so defined). 

Third Amended and Restated Credit Agreement

46

 

        SECTION 5.1.8    Lien Search; Recordings and Filings.

        (a)   The
Administrative Agent shall have received results of a recent search by a Person satisfactory to the Administrative Agent that there are no UCC or Tax lien filings on
any of the assets of any of the Borrower, its Subsidiaries, EMMT or any Midwest Related Party party to a Security Document in each relevant jurisdiction except for (i) Liens pursuant to the
Loan Documents and (ii) Permitted Liens. 

        (b)   Arrangements
reasonably satisfactory to the Administrative Agent and the Collateral Trustee shall have been made for the execution, reaffirmation, filing, registration
or recordation of all financing statements and all other documents required to be executed, reaffirmed, filed, registered or recorded in order to create, in favor of the Collateral Trustee for the
benefit of the Priority Lien Secured Parties, a perfected, first priority lien in each office in each jurisdiction in which such executions, reaffirmations, filings, registrations and recordations are
required to perfect the security interests created by the Security Documents, and any other action required in the judgment of the Administrative Agent or the Collateral Trustee to perfect such
security interests as such first priority liens. 

        SECTION 5.1.9    Collateral Trust Agreement.

        (a)   The
Administrative Agent shall have received a copy, certified by an Authorized Representative of the Borrower, of the Collateral Trust Agreement, which shall have been
duly executed and delivered by each of the intended parties thereto; 

        (b)   The
Administrative Agent, each Secured Debt Representative (as defined in the Collateral Trust Agreement) and the Collateral Trustee shall have received an
Officer's Certificate (as defined in the Collateral Trust Agreement) stating that the Borrower intends to secure additional Secured Debt (as defined in the Collateral Trust Agreement)
consisting of all Obligations of the Borrower under this Agreement which will be Priority Lien Debt (as defined in the Collateral Trust Agreement) permitted by each applicable Secured Debt
Document (as defined in the Collateral Trust Agreement) to be secured on a pari passu basis with all previously existing Priority Lien
Debt (as so defined) and that all other requirements set forth in the Collateral Trust Agreement as to the confirmation, grant or perfection of the Collateral Trustee's Lien to secure such
Indebtedness or Obligations in respect thereof have been satisfied; and 

        (c)   The
Collateral Trustee shall have received written notice from the Borrower specifying the name and address of the Administrative Agent for purposes of
Section 7.7 of the Collateral Trust Agreement. 

        SECTION 5.1.10    Title Policies.    The Administrative Agent shall have received date-down
endorsements to the Title Policies redating the Title Policies and all endorsements thereto as of the Closing Date. 

        SECTION 5.1.11    Projections and Rating Agency Presentations.    The Administrative Agent shall have received
copies certified by an Authorized Officer of the Borrower of: 

        (a)   satisfactory
financial projections for the Borrower for the 2007-2011 Fiscal Years of the Borrower, including Pro Forma consolidated financial
statements and calculations of the projected Debt to Capitalization Ratio; 

        (b)   satisfactory
environmental capital expenditure projections for the Borrower for the 2007-2013 Fiscal Years of the Borrower; and 

Third Amended and Restated Credit Agreement

47

 

        (c)   the
most recent financial projections and presentations provided to Moody's, S&P and Fitch in connection with issuance by the foregoing Rating Agencies of the most
recent Debt Ratings provided pursuant to Section 5.1.13. 

        SECTION 5.1.12    Approvals.

        (a)   (i)
All Governmental Approvals required to have been obtained on or prior to the Closing Date in connection with the transactions contemplated by the Loan Documents and
(ii) all material Governmental Approvals required to have been obtained on or prior to the Closing Date in connection with the conduct of the business of the Borrower (except, in each case,
additional filings contemplated by Section 5.1.8) shall have been obtained or made, be in full force and effect and, be final and any period for
the filing of notice of rehearing or application for judicial review of the issuance of each such Governmental Approval shall have expired without any such notice or application having been given or
made. No such Governmental Approval shall be the subject of any pending or threatened judicial or administrative proceeding. 

        (b)   All
consents and approvals required to be obtained from Persons other than Governmental Authorities in connection with the transactions contemplated by the Loan
Documents shall have been obtained and shall be in full force and effect, other than such consents or approvals, the failure of which to obtain, would not, individually or in the aggregate, cause a
Material Adverse Effect. 

        SECTION 5.1.13    Ratings.    The Administrative Agent shall have received ratings letters indicating the
Borrower's Debt Ratings. 

        SECTION 5.1.14    Energy Management Agreements.    The Administrative Agent shall have received a copy of the
Energy Management Agreements. 

        SECTION 5.1.15    Insurance.    The Administrative Agent shall have received evidence that the Collateral
Trustee is named as loss payee under the insurance policies of the Borrower to be maintained pursuant to Section 7.1.5 (other than insurance
policies maintained with respect to the Powerton Leased Facility and the Joliet Leased Facility to the extent required by the Powerton/Joliet Lease Operative Documents). 

        SECTION 5.2    Credit Extensions.    The obligation of each Lender and each Issuing Lender to make any Credit
Extension (including the initial Credit Extension) shall be subject to the satisfaction of each of the conditions precedent set forth in this  Section 5.2. 

        SECTION 5.2.1    Representations and Warranties; No Default.    Both before and after giving effect to any
Credit Extension (but, if any Default of the nature referred to in Section 8.1.5 shall have occurred with respect to any other Indebtedness,
without giving effect to the application, directly or indirectly, of the proceeds of such Credit Extension), the following statements shall be true and correct: 

        (a)   the
representations and warranties set forth in Article VI shall be true and correct in all material respects with
the same effect as if then made (unless stated to relate solely to an earlier date, in which case such representations and warranties shall be true and correct as of such earlier date); 

        (b)   except
as otherwise disclosed in public filings of the Borrower with the Securities and Exchange Commission prior to the Closing Date, no event or condition has occurred
since December 31, 2006 having a Material Adverse Effect as of the date of such Credit Extension; and 

        (c)   no
Default or Event of Default has occurred and is continuing or would result from such Credit Extension. 

Third Amended and Restated Credit Agreement

48

 

        SECTION 5.2.2    Borrowing or Letter of Credit Request.    The Administrative Agent shall have received, in the
case of Loans, a Borrowing Request for such Borrowing or, in the case of a Letter of Credit, a Letter of Credit Application for such Credit Extension. Each of the delivery of a Borrowing Request or
Letter of Credit Application and the acceptance by the Borrower of the proceeds of a Credit Extension shall constitute a representation and warranty by the Borrower that on the date of such Credit
Extension (both immediately before and after giving effect to such Credit Extension and the application of the proceeds thereof) the statements made in  Section 5.2.1 are true and correct.

        SECTION 5.3    Satisfactory Legal Form.    All documents executed or submitted pursuant hereto by or on behalf
of the Borrower or its Subsidiaries shall be satisfactory in form and substance to the Administrative Agent and its counsel. 

ARTICLE
VI 

REPRESENTATIONS
AND WARRANTIES 

        In
order to induce the Administrative Agent and each Lender to enter into this Agreement and to make Loans hereunder, the Borrower represents and warrants with respect to itself and its
Subsidiaries unto the Administrative Agent and each Lender as set forth in this Article VI. 

        SECTION 6.1    Financial Information.    The most recent consolidated balance sheet of the Borrower and the
related consolidated statements of income and cash flows of the Borrower, copies of which have been furnished to the Administrative Agent pursuant to  Section 5.1.6 on the Closing Date and pursuant
to Section 7.1.1 thereafter have been prepared in
accordance with GAAP consistently applied, and present fairly in all material respects the consolidated financial condition of the Borrower and its Subsidiaries as at the dates thereof and the results
of their operations for the periods then ended. 

        SECTION 6.2    Organization; Power.    Each of the Borrower and its Subsidiaries (a) is a corporation,
limited liability company or partnership validly organized and existing and in good standing under the laws of the state of its incorporation or formation, as the case may be, (b) is duly
qualified to do business and is in good standing as a corporation, limited liability company or partnership in each jurisdiction where the nature of its business requires such qualification and
(c) has all requisite corporate, company or partnership power and authority to enter into and perform its Obligations under this Agreement and each other Loan Document to which it is a party
and, in the case of the Borrower, to conduct the business of owning, leasing and operating the Facilities and the sale and marketing of wholesale electric power and other products and services related
thereto, except, with respect to clauses (b) and (c) above, where the failure to be so
qualified or be in good standing would not, individually or in the aggregate, cause a Material Adverse Effect. 

        SECTION 6.3    Due Authorization; Non-Contravention.    The execution of each Loan Document
executed as of Closing Date and the delivery and performance by the Borrower and its Subsidiaries of each Loan Document to which it is a party do not: 

        (a)   contravene
the Borrower's or its Subsidiaries' Organic Documents; 

        (b)   contravene
any Requirement of Law or Contractual Obligation, binding on or affecting Borrower or any Subsidiary, except where such contravention would not result in a
Material Adverse Effect; or 

        (c)   result
in, or require the creation or imposition of, any Lien (other than Permitted Liens) on any of the properties of the Borrower or any of its Subsidiaries. 

Third Amended and Restated Credit Agreement

49

 

        SECTION 6.4    Approvals.

        (a)   As
of the Closing Date, all Governmental Approvals required in connection with the transactions contemplated by the Loan Documents and the conduct of the business of
each of the Borrower and its Subsidiaries have been duly obtained or made and are in full force and effect other than (i) as may be required under existing Requirements of Law to be obtained,
given or renewed at any time after the Closing Date or from time to time after the Closing Date in connection with the transactions contemplated by the Loan Documents and (ii) which are routine
in nature and which cannot be obtained and such failure to obtain would not result in a Material Adverse Effect, or are not normally applied for, prior to the time they are required, and which the
Borrower has no reason to believe will not be timely obtained. All Governmental Approvals that have been obtained pursuant to clause (a) of this  Section 6.4 are final and any period for the filing of notice of rehearing or application for judicial review of the issuance of each such
Governmental Approval has expired without any such notice or application having been made. No such Governmental Approval is the subject of any pending or threatened judicial or administrative
proceeding. 

        (b)   As
of the Closing Date, all consents and approvals required to be obtained from Persons other than Governmental Authorities in connection with the transactions
contemplated by the Loan Documents have been obtained and are in full force and effect, other than such consents or approvals, the failure of which to obtain, would not, individually or in the
aggregate, cause a Material Adverse Effect. 

        SECTION 6.5    Accuracy of Information.

        (a)   All
material factual information furnished by the Borrower and its Affiliates in writing prior to the Closing Date to the Administrative Agent or any Lender for purposes
of or in connection with this Agreement or any transaction contemplated hereby (other than projections and other "forward-
looking" information) is true and materially accurate in every material respect on the date as of which such information is dated or certified, and to the knowledge of the Borrower as of the Closing
Date such information is not incomplete by omitting to state any material fact necessary in order to make such information not materially misleading. 

        (b)   All
projections and other "forward-looking" information heretofore or contemporaneously furnished by the Borrower and its Affiliates in writing to the Administrative
Agent or any Lender for the purposes of or in connection with this Agreement or any transaction contemplated hereby were prepared in good faith and are based on reasonable assumptions. 

        SECTION 6.6    Validity.    Each Loan Document to which the Borrower or any of its Subsidiaries is a party
constitutes, or, upon the due execution and delivery thereof by the Borrower or such Subsidiary, will constitute, the legal, valid and binding obligation of the Borrower or such Subsidiary enforceable
in accordance with its terms except as may be limited by bankruptcy, insolvency or other similar laws affecting the enforcement of creditors' rights generally and general principles of equity. 

        SECTION 6.7    Compliance with Law and Contractual Obligations.    Each of the Borrower and its Subsidiaries is
in compliance with all Requirements of Law and Contractual Obligations applicable to it, except to the extent that the failure to comply therewith would not have a Material Adverse Effect. 

        SECTION 6.8    Regulations T, U and X.    Neither the Borrower nor its Subsidiaries is engaged in the
business of extending credit for the purpose of purchasing or carrying margin stock, and no proceeds of any Loans will be used for a purpose which violates, or would be inconsistent with, Board
Regulation T, U or X. Terms for which meanings are provided in Board Regulation T, U or X or any 

Third Amended and Restated Credit Agreement

50

 

regulations
substituted therefor, as from time to time in effect, are used in this Section 6.8 with such meanings. 

        SECTION 6.9    Litigation.    There is no pending or, to the knowledge of the Borrower, threatened litigation,
action, proceeding, investigation or labor controversy against the Borrower or any of its Subsidiaries or any of their properties, businesses, assets or revenues or affecting any Governmental Approval
required to be in full force and effect by Section 6.4, which, if adversely determined (taking into account any insurance proceeds payable under
a policy where the insurer has accepted coverage without any reservations), would have a Material Adverse Effect. 

        SECTION 6.10    Ownership of Properties.

        (a)   Each
of Borrower and its Subsidiaries owns good and marketable title to, or a valid leasehold in or other enforceable interest in, all properties and assets, real and
personal, tangible and intangible, of any nature whatsoever (including patents, trademarks, trade names, service marks and copyrights) purported to be owned, leased or held by it, free and clear of
all Liens, charges or claims (including infringement claims with respect to patents, trademarks, copyrights and the like) except as permitted pursuant to  Section 7.2.2. 

        (b)   As
of the Closing Date, the Borrower owns and has good marketable title to a 100% interest in the Mortgaged Facilities, free and clear of all Liens other than Permitted
Liens. The Borrower owns and (to the extent applicable) has good and marketable title to the Collateral (other than the Mortgaged Facilities and the after-acquired property contemplated by the
Security Documents) purported to be covered by the Security Documents to which it is a party free and clear of all Liens other than Permitted Liens. The Borrower is lawfully possessed of a valid and
subsisting estate in and to any and all easements (except for easements that, the absence of which, would not have a material adverse effect on the operation of a Mortgaged Facility) necessary for the
ownership, leasing, occupation, construction, repair, operation, maintenance, use and financing (collectively, "Operation") of the Mortgaged Facilities
free and clear of all Liens other than Permitted Liens, and has obtained all licenses and permits required by applicable Requirements of Law and all easements and access rights necessary (except for
easements and access rights that, the absence of which, would not have a material adverse effect on the operation of a Mortgaged Facility) for the Operation of the Mortgaged Facilities and enjoys
peaceful and undisturbed possession of all of the "Mortgaged Property" (as defined in the relevant Mortgaged Facility Mortgage) (subject only to Permitted Liens) in each of the foregoing cases
to the extent that is necessary for the current state of Operation of the Mortgaged Facilities. 

        SECTION 6.11    Taxes.    Each of the Borrower and its Subsidiaries has filed all Tax Returns and reports
required by law to have been filed by it and has paid all Taxes thereby shown to be owing, except any such Taxes which are being diligently contested in good faith by appropriate proceedings and for
which adequate reserves in accordance with GAAP shall have been set aside on its books. 

        SECTION 6.12    Investment Company Act; Public Utility Holding Company Act; Other Regulations.

        (a)   Neither
the Borrower nor its Subsidiaries is subject to any regulation as an "investment company" under the Investment Company Act of 1940, as amended. 

        (b)   As
of the Closing Date, the Borrower (i) is not subject to regulation as an alternative retail electric supplier under the laws of the State of Illinois,
(ii) is interconnected with the high voltage network and has access to transmission services and ancillary services to sell wholesale electric power and (iii) has the authority to sell
wholesale electric power at market-based rates. 

Third Amended and Restated Credit Agreement

51

 

        (c)   As
of the Closing Date, neither the Borrower nor any Subsidiary of the Borrower (i) is subject to regulation under PUHCA that would have effect of preventing the
execution and performance of its obligations under each Loan Document to which it is a party or (ii) is or will be subject to regulation as a "public utility" under the laws of the State
of Illinois. 

        SECTION 6.13    Environmental Warranties.    Except as could not, individually, or would not, in the aggregate,
be reasonably expected to have a Material Adverse Effect: 

        (a)   (i)
All facilities and property owned, leased or operated by each of the Borrower and its Subsidiaries have been, and continue to be, owned, leased or operated by the
Borrower or such Subsidiary in compliance with all applicable Environmental Laws and (ii) each of the Borrower and its Subsidiaries is, and within the period of all applicable statutes of
limitation has been, in compliance with all applicable Environmental Laws. 

        (b)   Except
as otherwise disclosed in public filings of the Borrower with the Securities and Exchange Commission prior to the Closing Date, there are no pending or, to the
knowledge of the Borrower, threatened (i) claims, complaints, notices or requests for information received by the Borrower or any of its Subsidiaries with respect to any alleged violation by
the Borrower or any of its Subsidiaries of any applicable Environmental Law, or (ii) complaints, notices or inquiries to the Borrower or any of its Subsidiaries regarding potential liability
under any applicable Environmental Law. 

        (c)   Each
of the Borrower and its Subsidiaries has obtained and is in compliance with all Governmental Approvals required, other than those that will be obtained in due
course promptly after the Closing Date, under any Environmental Law necessary for the Borrower's or its Subsidiaries' business. 

        (d)   No
property now or previously owned, leased or operated by the Borrower or any of its Subsidiaries is listed or, to the knowledge of the Borrower, is proposed for
listing on the National Priorities List pursuant to any Environmental Law, on the CERCLIS or on any similar state or local list of sites requiring investigation or clean-up. 

        (e)   To
the knowledge of the Borrower, no conditions exist at, on, under or about any property now or previously owned or leased by the Borrower or its Subsidiaries or at any
other location (including any location to which Hazardous Materials have been sent for re-use or for recycling or for treatment, storage or disposal) which, with the passage of time, or
the giving of notice or both, would give rise to liability under any applicable Environmental Law. 

        SECTION 6.14    The Obligations.    The Loans and all other Obligations under the Loan Documents are senior
secured Indebtedness of the Borrower and its Subsidiaries ranking at least pari passu with all other senior secured Indebtedness of the Borrower
and its Subsidiaries. 

        SECTION 6.15    Pension and Welfare Plans.    During the consecutive twelve-month period prior to each date as
of which the following representations are made or deemed made, and prior to the date of any Borrowing hereunder, no steps have been taken to terminate any Pension Plan; no contribution failure has
occurred with respect to any Pension Plan sufficient to give rise to a Lien under Section 302(f) of ERISA or Section 412 of the Code; no condition exists or event or transaction has
occurred with respect to any Pension Plan which could reasonably be expected to result in the incurrence by the Borrower or any of its Subsidiaries or any member of the Controlled Group of any
material liability (other than liabilities incurred in the ordinary course of maintaining the Pension Plan), fine or penalty and none of the following events or conditions, either individually or in
the aggregate, has resulted or is reasonably likely to result in a material liability to the Borrower or any of its Subsidiaries or any member of the Controlled Group: (i) a Reportable Event;
(ii) a complete or partial 

Third Amended and Restated Credit Agreement

52

 

withdrawal
from any Multiemployer Plan by the Borrower or any of its Subsidiaries or any member of the Controlled Group; (iii) any liability of the Borrower or any of its Subsidiaries or any
member of the Controlled Group under ERISA if the Borrower or any of its Subsidiaries or any member of the Controlled Group were to withdraw completely from all Multiemployer Plans as of the annual
valuation date most closely preceding the date on which this representation is made or deemed made; or (iv) the Reorganization or Insolvency of any Multiemployer Plan. None the Borrower or any
of its Subsidiaries or any member of the Controlled Group has any contingent liability with respect to any post-retirement benefit under a Welfare Plan which could reasonably be expected
to have a Material Adverse Effect, other than liability for continuation coverage described in Part 6 of Title I of ERISA. 

        SECTION 6.16    Solvency.    The Borrower, together with its respective Subsidiaries, taken as a whole, will be
Solvent as of the Closing Date after giving effect to the Borrowing as of the date hereof and to the application of the proceeds therefrom. 

ARTICLE
VII 

COVENANTS 

        SECTION 7.1    Affirmative Covenants.    The Borrower agrees with the Administrative Agent and each Lender
that, until the Commitments have terminated and all Loans and all other Obligations under the Loan Documents have been paid and performed in full and all Letters of Credit shall have expired or
terminated and all LC Disbursements shall have been reimbursed, the Borrower shall, and shall cause each of its Subsidiaries to, perform the obligations set forth in this  Section 7.1.

        SECTION 7.1.1    Financial Information, Reports, Notices.    The Borrower shall furnish, or shall cause to be
furnished, to the Administrative Agent copies of the following financial statements, reports, notices and information: 

        (a)   as
soon as available and in any event within sixty (60) days after the end of each of the first three Fiscal Quarters of each Fiscal Year of the Borrower,
consolidated balance sheets of the Borrower (which will include results for its Consolidated Subsidiaries) as of the end of such Fiscal Quarter and consolidated statements of income and cash flows of
the Borrower (which will include results for its Consolidated Subsidiaries) for such Fiscal Quarter and for the period commencing at the end of the previous Fiscal Year and ending with the end of such
Fiscal Quarter, certified by an Authorized Representative of the Borrower with responsibility for financial matters; 

        (b)   as
soon as available and in any event within 120 days after the end of each Fiscal Year of the Borrower, commencing with the 2007 Fiscal Year, a copy of the
annual audit report for such Fiscal Year for the Borrower (which will include results for its Consolidated Subsidiaries), including therein consolidated balance sheets of the Borrower (which will
include results for its Consolidated Subsidiaries) as of the end of such Fiscal Year and consolidated statements of income and cash flows of the Borrower (which will include results for its
Consolidated Subsidiaries) for such Fiscal Year, and accompanied by the unqualified opinion of Pricewaterhouse Coopers LLP or other internationally recognized independent auditors selected by
the Borrower to the effect that such consolidated financial statements present fairly in all material respects the financial condition and results of operations of the Borrower and its Subsidiaries on
a consolidated basis in accordance with GAAP consistently applied; 

        (c)   as
soon as possible after the end of the first and third Fiscal Quarters of each Fiscal Year, an officer's certificate stating the outstanding principal amounts of each
of the Powerton/Joliet Lease Intercompany Notes and a statement of transactions reconciling such amounts to the last day of the immediately preceding Fiscal Quarter; 

Third Amended and Restated Credit Agreement

53

  

        (d)   concurrently
with the delivery of the financial statements referred to in Sections 7.1.1(a)
and (b), a certificate, executed by an Authorized Representative of the Borrower with responsibility for financial matters, showing the Debt to
Capitalization Ratio as at the last day of the immediately preceding Fiscal Quarter, in reasonable detail with appropriate calculations and computations; 

        (e)   as
soon as possible and in any event within five (5) Business Days after any Authorized Representative of the Borrower obtains knowledge of the occurrence of
(i) each Default under this Agreement and (ii) any default under any other material agreement to which the Borrower, any of its Subsidiaries, EMMT or any Midwest Related Party is a party
or any termination thereof together with a statement of such Authorized Representative setting forth details of such Default, default or termination and the action which the Borrower, such Subsidiary,
EMMT or such Midwest Related Party has taken and proposes to take with respect thereto; 

        (f)    as
soon as possible and in any event within five (5) Business Days after the commencement of, or the occurrence of any material adverse development with respect
to, any litigation, action, proceeding, or labor controversy of the type described in Section 6.9, notice thereof and, upon request of the
Administrative Agent, copies of all documentation relating thereto (other than documentation subject to the attorney-client privilege); 

        (g)   promptly
after the sending or filing thereof, copies of all reports and registration statements which the Borrower files with the Securities and Exchange Commission or
any national securities exchange; 

        (h)   immediately
upon becoming aware of the institution of any steps by the Borrower, any of its Subsidiaries or any other Person to terminate any Pension Plan (other than a
standard termination under ERISA Section 4041(b)), or the failure to make a required contribution to any Pension Plan if such failure is sufficient to give rise to a Lien under
Section 302(f) of ERISA or Section 412 of the Code, or the taking of any action with respect to a Pension Plan which could result in the requirement that the Borrower furnish a bond or
other security to the PBGC or such Pension Plan, or the occurrence of any event with respect to any Pension Plan which could result in the incurrence by the Borrower or any member of the Controlled
Group of any material liability (other than liabilities incurred in the ordinary course of maintaining the Pension Plan), fine or penalty, or any increase in the contingent liability of the Borrower
with respect to any post-retirement Welfare Plan
benefit the occurrence or expected occurrence of any Reportable Event or the termination, Reorganization or Insolvency of any Multiemployer Plan or the complete or partial withdrawal by the Borrower
or any member of the Controlled Group from a Multiemployer Plan, notice thereof and copies of all documentation relating thereto; 

        (i)    as
soon as possible and in any event within five (5) Business Days after any Authorized Representative of the Borrower obtains knowledge of the occurrence
thereof, notice that any Governmental Authority may revoke, or refuse to grant or renew, or materially modify, any material Governmental Approval then required to be in full force and effect, as
contemplated by Section 6.4; and 

        (j)    from
time to time, with reasonable promptness, such other information regarding the Borrower, its Subsidiaries, EMMT or any Midwest Related Party (to the extent
reasonably available to the Borrower and its Subsidiaries) as the Administrative Agent or any Lender may reasonably request. 

        SECTION 7.1.2    Continuation of Business and Maintenance of Existence.    The Borrower shall continue to
engage in the business of owning, leasing and operating the Facilities and the sale and 

Third Amended and Restated Credit Agreement

54

 

marketing
of wholesale electric power and other products and services related thereto. The Borrower shall not, and shall cause its Subsidiaries to not, engage in any business other than owning,
leasing and operating electrical generating assets and selling and marketing wholesale electric power and other products and services related thereto. The Borrower shall, and shall cause each of its
Subsidiaries to, preserve, renew and keep in full force and effect its corporate, limited liability company or partnership existence and take all reasonable action to maintain all material rights,
privileges and franchises necessary or desirable in the normal conduct of its business, except, in each case, as otherwise permitted by  Section 7.2.3. 

        Notwithstanding
the preceding, nothing contained in this Section 7.1.2 shall prevent the Borrower from mothballing,
decommissioning, or otherwise removing from productive service or use any Non-Core Facility (if the Borrower has determined that such Non-Core Facility is economically
or technologically obsolete or otherwise surplus to the Borrower's needs or is no longer useful in its trade or business). 

        SECTION 7.1.3    Compliance with Requirements of Law and Contractual Obligations.    The Borrower shall, and
shall cause its Subsidiaries to, comply with all Requirements of Law (including all applicable zoning, use, subdivision or similar law, rule or regulation) and Contractual Obligations, such compliance
to include the payment, before the same become delinquent, of all taxes, assessments and governmental charges or levies, except to the extent non-compliance would not have a Material
Adverse Effect. 

        SECTION 7.1.4    Maintenance of Facilities.    The Borrower shall (a) maintain the Maintained Facilities
in all material respects (i) in good condition, repair and working order (ordinary wear and tear excepted), except where the failure so to do would not have a Material Adverse Effect,
(ii) in accordance with Prudent Industry Practice and (iii) in accordance with the terms of all insurance policies required to be maintained pursuant to  Section 7.1.5, and (b) make
such repairs, renewals, replacements, betterments and improvements to the Maintained Facilities as in the
reasonable judgment of the Borrower are necessary so that the Maintained Facilities may be operated in accordance with their intended purpose. 

        Notwithstanding
the preceding, nothing contained in this Section 7.1.4 shall (a) prevent the Borrower from mothballing,
decommissioning, or otherwise removing from productive service or use or (b) require the Borrower to comply with this Section 7.1.4 with
respect to any Non-Core Facility (if the Borrower has determined that such Non-Core Facility is economically or technologically obsolete or otherwise surplus to the
Borrower's needs or is no longer useful in its trade or business). 

        SECTION 7.1.5    Insurance.

        (a)   The
Borrower shall maintain or cause to be maintained with financially sound and reputable insurance companies, insurance for such amounts against such risks, loss,
damage and liability as are customarily insured against by other enterprises of like size and type as that of the Facilities, subject to the availability of such coverage, including the deductible and
tenor for business interruption insurance referred to below, on commercially reasonable terms, all on terms and conditions which are in accordance with Prudent Industry Practice and shall include
business interruption insurance with a deductible not to exceed sixty (60) days and a tenor no shorter than one year; 

        (b)   All
such policies of casualty, third party liability and business interruption insurance shall: 

        (i)    provide
that, with respect to third party liability insurance, the Secured Parties shall be named as additional insureds; 

Third Amended and Restated Credit Agreement

55

 

        (ii)   name
the Collateral Trustee as a loss payee (other than insurance policies maintained with respect to the Powerton Leased Facility and the Joliet Leased Facility to the
extent required by the Powerton/Joliet Lease Operative Documents); 

        (iii)  provide
that (x) no cancellation or termination of such insurance and (y) no reduction in the limits of liability of such insurance shall be effective
until thirty (30) days after written notice is given by the insurers to the Administrative Agent and the Collateral Trustee of such cancellation, termination, reduction or change; 

        (iv)  waive
all claims for insurance premiums or commissions or additional premiums or assessments against the Secured Parties; and 

        (v)   waive
any right of the insurers to setoff or counterclaim or to make any other deductions, whether by way of attachment or otherwise, as against the Secured Parties. 

        Notwithstanding
the preceding, with respect to any Non-Core Facility that the Borrower has determined is economically or technologically obsolete or otherwise surplus to the
Borrower's needs or no longer useful in its trade or business, the Borrower shall not be required to maintain casualty or business interruption insurance for such facilities. 

        SECTION 7.1.6    Books and Records.    The Borrower shall, and shall cause its Subsidiaries to, keep books and
records which accurately reflect all of its business affairs and transactions and permit the Administrative Agent and each Lender (at such Lender's expense) or any of their respective
representatives, at reasonable times and intervals upon reasonable prior notice, to visit all of its offices and sites and, to discuss its financial matters with its officers and independent public
accountant. The Borrower shall, at any reasonable time and from time to time upon reasonable prior notice, permit the Administrative Agent and the Lenders or any of their respective agents or
representatives to examine and make copies of and abstracts from the records and books of account of the Borrower and its Subsidiaries; provided that by
virtue of this Section 7.1.6 the Borrower shall not be deemed to have waived any right to confidential treatment of the information obtained,
subject to the provisions of applicable law or court order. 

        SECTION 7.1.7    Environmental Covenant.    The Borrower shall, and shall cause its Subsidiaries to, and, with
respect to clause (a) below, shall take all reasonable efforts to ensure that all of its tenants, subtenants, contractors, subcontractors and
invitees shall: 

        (a)   comply
with all applicable Environmental Laws and obtain, comply with and maintain all necessary Governmental Approvals required under any applicable Environmental Law,
in each case, except where such noncompliance or failure, individually or in the aggregate, could not reasonably be expected to result in a Material Adverse Effect; and 

        (b)   provide
copies of information to evidence compliance with this Section 7.1.7 to the extent reasonably
requested by the Administrative Agent from time to time. 

        SECTION 7.1.8    Further Assurances.

        (a)   Upon
written request of the Administrative Agent, the Borrower shall, and shall cause its Subsidiaries to, promptly perform or cause to be performed any and all acts and
execute or cause to be executed any and all documents (including, financing statements and continuation statements) for filing under the provisions of the UCC or any other Requirement of Law which are
necessary or advisable to maintain in favor of the Collateral Trustee, for the benefit of the Secured Parties, Liens on the Collateral that are duly perfected in accordance with all applicable
Requirements of Law. 

Third Amended and Restated Credit Agreement

56

 

        (b)   If
the Borrower or any of its Subsidiaries shall at any time acquire any material interest in all real and personal property not covered by the Security Documents
(to the extent that any such property is of a type that has been expressly included in the Security Documents), the Borrower shall, and shall cause its Subsidiaries to, promptly, upon such
acquisition, execute, deliver and record a supplement to the relevant Security Documents or other documentation (including mortgages, security documents, financing statements, opinions, title
insurance, surveys and other documents), reasonably satisfactory in form and substance to the Collateral Trustee, subjecting such interests to the security interests created by such Security Documents
and ensuring that the security interest in such interest will be a valid and an effective interest on terms comparable to the security interest of the Collateral Trustee in the Collateral;  provided,
that this clause (b) shall not require, at any time, the granting of a mortgage or
other lien to the Collateral Trustee on any Non-Core Facility. 

        (c)   The
Borrower shall (i) promptly deliver to the Collateral Trustee a copy of any notice it receives in connection with the foreclosure of any mortgage permitted to
exist pursuant to Section 7.2.2, which foreclosure would adversely effect the Borrower's right to use any portion of the Mortgaged Facilities,
and (ii) redeem the portion of the Mortgaged Facilities affected by such foreclosure, prior to it being foreclosed; provided, that the Collateral
Trustee may redeem such portion to the extent the Lenders may deem necessary or advisable. 

        (d)   If
the Borrower or any of its Subsidiaries acquires or creates another Subsidiary after the Closing Date, that newly acquired or created Subsidiary will become a
guarantor of the Priority Lien Debt and Parity Lien Debt by executing and delivering to the Priority Debt Representative and the Collateral Trustee, a Subsidiary Guarantee within ten (10) days
of the date on which such Subsidiary was acquired or created. 

        (e)   The
Borrower shall make all commercially reasonable efforts to provide for the inclusion of customary assignment provisions for the benefit of the Secured Parties in any
material contracts exceeding six (6) months in duration entered into in connection with the Facilities (other than the Powerton Leased Facility and the Joliet Leased Facility). 

        SECTION 7.1.9    Financial Covenant.    The Borrower shall maintain at the end of each of its Fiscal Quarters,
the Debt to Capitalization Ratio at no greater than 0.60 to 1.00. 

        SECTION 7.1.10    Use of Proceeds.    The proceeds of the Loans will be used by the Borrower to Refinance the
Revolving Loans under (and as defined in) the Existing Credit Agreement) and for general corporate and working capital purposes of the Borrower and its Subsidiaries in the ordinary course
of business. 

        SECTION 7.1.11    Separateness.    The Borrower will: 

        (a)   act
solely in its name and through its duly authorized officers or agents in the conduct of its business; 

        (b)   conduct
its business solely in its own name, in a manner not misleading to other persons as to its identity (without limiting the generality of the foregoing, all oral
and written communications (if any), including letters, invoices, purchase orders, contracts, statements, and applications are made and shall continue to be made solely in the name of the
Borrower, if related to the Borrower); 

        (c)   provide
for the payment of its own operating expenses and liabilities from its own funds; and 

Third Amended and Restated Credit Agreement

57

 

        (d)   obtain
proper authorization from its directors or member(s), as required by its Organic Documents for all company actions of the Borrower. 

        SECTION 7.2    Negative Covenants.    The Borrower agrees with the Administrative Agent and each Lender that,
until the Commitments have terminated and all Loans and all other Obligations under the Loan Documents have been paid and performed in full, the Borrower will, and will cause its Subsidiaries to,
perform the obligations set forth in this Section 7.2. 

        SECTION 7.2.1    Restrictions on Secured Indebtedness.    The Borrower shall not, and shall not permit any of
its Subsidiaries to, create, incur, assume or suffer to exist any secured Indebtedness other than (a) (i) Capitalized Lease Liabilities and Operating Lease Liabilities outstanding on
March 31, 2007 and set forth on Schedule 7.2.1(a) and (ii) Capitalized Lease Liabilities and Operating Lease Liabilities entered
into in the ordinary course of business not to exceed at any time an aggregate notional principal amount of $100,000,000, including in the case of each of clause (i) and clause (ii)
above, Capitalized Lease Liabilities and Operating Lease Liabilities entered into in the ordinary course of business to replace or refinance Capitalized Lease Liabilities or Operating Lease
Liabilities permitted pursuant to this Section 7.2.1(a), (b) secured Indebtedness of any kind whatsoever existing on the Closing Date,
(c) secured Indebtedness permitted to be secured pursuant to Section 7.2.2; or (d) Permitted Refinancing Indebtedness. 

        SECTION 7.2.2    Liens.    The Borrower shall not, and shall not permit its Subsidiaries to, create, incur,
assume or suffer to exist any Lien upon any of its property, revenues or assets, whether now owned or hereafter acquired, except: 

        (a)   any
Lien existing on the property of the Borrower or its Subsidiaries on the Closing Date (including (i) the Joliet Shared Facilities Agreements and
(ii) any easements, rights of way, reservations, restrictions, covenants, party-wall agreements, agreements for joint or common use, landlord's rights of distraint and other similar
imperfections in title on real estate set forth as an exception in the Title Policies; provided, that such easements and imperfections are not incurred
in connection with any Indebtedness); provided, that such Liens do not materially (individually or in the aggregate) (i) interfere with the use
of the property and assets of the Borrower or (ii) affect the operation or value of the Mortgaged Facilities or the interest of the Secured Parties in the Collateral; 

        (b)   Liens
for Taxes, assessments or other governmental charges or levies not yet delinquent or thereafter payable without penalty or which are being contested in good faith
by appropriate proceedings promptly instituted and diligently prosecuted and for which adequate reserves in accordance with GAAP shall have been set aside on its books; 

        (c)   Liens
of carriers, warehousemen, mechanics, materialmen and landlords incurred in the ordinary course of business for sums not overdue or which are being diligently
contested in good faith by appropriate proceedings and for which adequate reserves in accordance with GAAP shall have been set aside on its books; 

        (d)   Liens
incurred in the ordinary course of business in connection with workmen's compensation, unemployment insurance or other forms of governmental insurance
or benefits; 

        (e)   Liens
granted as security for the performance of bids, tenders, statutory obligations, operating leases and contracts (other than for borrowed money) entered into in the
ordinary course of business or to secure obligations on surety or appeal bonds; 

        (f)    judgment
Liens in existence less than thirty (30) days after the entry thereof so long as no enforcement, levy, collection or foreclosure proceeding has commenced
or with respect to which 

Third Amended and Restated Credit Agreement

58

 

execution
has been stayed or the payment of which is covered in full (subject to a customary deductible) by insurance maintained with responsible insurance companies; 

        (g)   extensions
or renewals of any Lien otherwise permitted to be incurred under this Section 7.2.2 securing
Indebtedness (including Permitted Refinancing Indebtedness) in an amount not exceeding the principal amount of, and accrued interest on, the Indebtedness secured by such Lien as so extended or renewed
at the time of such extension or renewal; provided that such Lien shall apply only to the same property theretofore previously securing such
Indebtedness; 

        (h)   Liens
to secure Environmental CapEx Debt that encumber only the assets purchased, installed or otherwise acquired with the proceeds of such Environmental
CapEx Debt; 

        (i)    purchase
money Liens securing Indebtedness permitted by Section 7.2.1;  provided that such Liens do not encumber any assets other than those acquired or
constructed with the proceeds of such Indebtedness; 

        (j)    Liens
on cash collateral securing investments and Guarantee obligations permitted by Section 7.2.1; 

        (k)   Liens
created pursuant to the Powerton/Joliet Lease Operative Documents; 

        (l)    easements,
rights of way, reservations, restrictions, covenants, party-wall agreements, agreements for joint or common use, landlord's rights of distraint
and other similar imperfections in title on real estate; provided that such easements and imperfections are not incurred in connection with any
Indebtedness, do not materially (individually or in the aggregate) (i) interfere with the use of the property and assets of the Borrower or (ii) affect the operation or value of the
Mortgaged Facilities or the interest of the Secured Parties in the Collateral; 

        (m)  Liens
for the benefit of the holders of Priority Lien Debt in accordance with the Collateral Trust Agreement securing Priority Lien Debt; 

        (n)   Liens
for the benefit of the holders of Parity Lien Debt in accordance with the Collateral Trust Agreement securing Parity Lien Debt; and 

        (o)   Liens
on cash and investments (i) deposited by the Borrower or any of its Subsidiaries in margin accounts with or on behalf of futures contract brokers or paid
over to other counterparties or (ii) pledged or deposited as collateral to a contract counterparty or issuer of surety bonds by the Borrower or any of its Subsidiaries, in the case of
clause (i) or (ii), to secure obligations with respect to Commodity Hedge and Power Sales Agreements permitted pursuant to Section 7.2.10. 

        SECTION 7.2.3    Consolidation, Merger.    The Borrower shall not directly or indirectly,
(a) consolidate or merge with or into another Person (whether or not the Borrower is the surviving entity), (b) sell, assign, transfer, convey or otherwise dispose of all or
substantially all of the properties or assets of the Borrower or its Subsidiaries taken as a whole, in one or more related transactions, to another Person or (c) lease all or substantially all
of its properties or assets, in one or more related transactions, to any other Person; provided, that the Borrower may (i) merge with an
Affiliate solely for purposes of reconstituting the Borrower in another jurisdiction or (ii) reorganize as either (x) a corporation organized or existing under the laws of the
United States, any state thereof or the District of Columbia or (ii) a partnership or limited liability company organized or existing under the laws of the United States, any
state thereof or the District of Columbia that has at least one Subsidiary that is a corporation organized or existing under the laws of the United States, any state thereof or the District
of Columbia. 

Third Amended and Restated Credit Agreement

59

 

        Notwithstanding
anything in this Section 7.2.3 to the contrary, the Borrower shall be permitted to reorganize as a
corporation, so long as such reorganization is not adverse to the Lenders (it being recognized that such reorganization shall not be deemed adverse to the Lenders solely because (i) of
the accrual of deferred tax liabilities resulting from such entity or (ii) the successor surviving corporation (x) is subject to income tax as a corporate entity or (y) is
considered to be an "includable corporation" of an affiliated group of corporations within the meaning of the Code or any similar state or local law). 

        SECTION 7.2.4    Asset Sales.    The Borrower shall not, and shall not permit its Subsidiaries to, sell,
transfer, lease, contribute or otherwise convey, or grant options, warrants or other rights with respect to, any part of its assets (including accounts receivable and capital stock of or other
ownership interests in Subsidiaries) to any Person (each such event, an "Asset Sale"). 

        Notwithstanding
the preceding, the following items shall not be deemed to be Asset Sales: 

        (i)    a
disposition resulting from the exercise by a Governmental Authority of its claimed or actual power of eminent domain, in each case without compensation; 

        (ii)   the
sale or other disposition of cash or Cash Equivalent Investments; 

        (iii)  any
sale or transfer of fuel or other related assets, including assets related to trading activities; 

        (iv)  termination
or unwinding of Commodity Hedge and Power Sales Agreements; 

        (v)   the
sale or other disposition of assets in one transaction or a series of transactions on an arm's length basis, the sales proceeds of which shall not exceed 10% of
Consolidated Net Tangible Assets as of the most recently ended fiscal quarter of the Company in the aggregate value thereof for all such transactions since Closing Date; 

        (vi)  the
sale or other disposition of assets in one transaction or a series of transactions on an arm's length basis, the sales proceeds of which shall not exceed 30% of
Consolidated Net Tangible Assets as of the most recently ended fiscal quarter of the Company in the aggregate value thereof for all such transactions since the Closing Date (inclusive of sales and
dispositions of assets referred to in clause (v) above), if within 6 months after the receipt of any net proceeds from such Asset Sale, the Borrower (or the applicable Subsidiary,
as the case may be) applies or enters into a binding commitment to apply such net proceeds: (1) to repay any Environmental CapEx Debt permitted to be incurred herein and/or cash collateralize
letters of credit that comprise a part of such Environmental CapEx Debt, and, if the Environmental CapEx Debt repaid is revolving credit Indebtedness, to correspondingly reduce commitments with
respect thereto; (2) to repay Priority Lien Debt and/or create Liens on such net proceeds in favor of the Collateral Trustee to cash collateralize letters of credit that comprise a part of
Priority Lien Debt, and, if the Priority Lien Debt is revolving credit Indebtedness, to correspondingly reduce commitments with respect thereto; (3) to acquire other assets that are not
classified as current assets under GAAP and that are used or useful in the Borrower's business as permitted under Section 7.1.8; or (4) any combination of the (1) through
(3) of this Section 7.2.4(vi); and 

        (vii) the
sale or other disposition of any Non-Core Facility. 

        SECTION 7.2.5    Investments.    The Borrower shall not, and shall not permits its Subsidiaries to, create or
acquire, make, incur, assume or suffer to exist any Investment in any other Person, except: 

        (a)   Investments
existing on the Closing Date; 

Third Amended and Restated Credit Agreement

60

 

        (b)   cash,
Cash Equivalent Investments or Permitted Investments under, and as defined in, the Borrower Security Agreement (in each case, held in Bank Accounts or
securities accounts in which the Borrower shall have granted a security interest as Collateral and which security interest shall constitute a first priority perfected security interest); 

        (c)   Investments
evidenced by the Powerton/Joliet Lease Intercompany Notes; 

        (d)   Investments
in new Subsidiaries acquired or created in accordance with Section 7.1.8; 

        (e)   any
Permitted Tax Payments; and 

        (f)    Investments
in connection with the provision of Permitted Marketing Support. 

        SECTION 7.2.6    Transactions with Affiliates.

        (a)   The
Borrower shall not, and shall not permit its Subsidiaries to, enter into or suffer or permit to exist, any Transaction with an Affiliate unless such arrangement or
contract is fair and reasonable to the Borrower or such Subsidiary and is an arrangement or contract of the kind which would be entered into by a prudent Person in the position of the Borrower or such
Subsidiary with a Person which is not one of its Affiliates. 

        (b)   The
Borrower shall not, and shall not permit any of its Affiliates to terminate or amend, supplement, otherwise modify or waive any term of the Energy Management
Agreements in (i) any manner materially adverse with respect to their payment terms or (ii) otherwise in a manner which would result or could reasonably be expected to result in a
Material Adverse Effect without the written consent of the Required Lenders which consent shall not be unreasonably withheld or delayed. 

        Notwithstanding
the preceding, (I) the Powerton/Joliet Lease Transaction and the transactions contemplated by the Powerton/Joliet Lease Operative Documents, (II) Commodity
Hedge and Power
Sales Agreements by or for the benefit of the Borrower, whether directly with unaffiliated third parties or with EMMT, and the provision of Permitted Marketing Support and (III) any Permitted
Tax Payment (or agreement pursuant to which a Permitted Tax Payment is made or required to be made) shall be deemed not to be a Transaction with an Affiliate for the purposes of this  Section 7.2.6. 

        SECTION 7.2.7    Restricted Payments.    The Borrower shall not, and shall not permit any of its Subsidiaries
to, directly or indirectly (all such payments and other actions set forth in clauses (a)
through (e) below, collectively, "Restricted Payments"): 

        (a)   declare
or pay any dividend or make any other payment or distribution on account of the Borrower's Equity Interests (including any payment in connection with any merger
or consolidation involving the Borrower) or to the direct or indirect holders of the Borrower's Equity Interests in their capacity as such (other than dividends or distributions payable in Equity
Interests of the Borrower or dividends or distributions payable to the Borrower); 

        (b)   purchase,
redeem or otherwise acquire or retire for value (including in connection with any merger or consolidation involving the Borrower) any Equity Interests of
the Borrower; 

        (c)   make
any payment on or with respect to, or make any transfer to or for the benefit of, or purchase, redeem, defease or otherwise acquire or retire for value any
Affiliated Indebtedness of the Borrower or any of its Subsidiaries (excluding any intercompany Indebtedness between or among the Borrower and any of its Subsidiaries); 

Third Amended and Restated Credit Agreement

61

  

        (d)   make
any payment on or with respect to, or make any transfer to or for the benefit of, or purchase, redeem, defease or otherwise acquire or retire for value any
Subordinated Indebtedness, except a payment of interest or principal at the stated maturity thereof; or 

        (e)   make
any Investments not otherwise permitted pursuant to Section 7.2.5; 

except
that, the Borrower and its Subsidiaries may make Restricted Payments, provided that no Default or Event of Default has occurred and is continuing
or would occur as a after giving effect to such Restricted Payment (other than any Default or Event of Default that is cured as a result of such Restricted Payment). 

        Notwithstanding
anything in this Section 7.2.7 to the contrary, the Borrower may repurchase, redeem, defease or otherwise
acquire or retire for value Subordinated Indebtedness of the Borrower or any of its Subsidiaries with the proceeds from a substantially concurrent incurrence of Permitted Refinancing Indebtedness;  provided, that, no Default or Event of Default has occurred and is continuing or would occur as a result of, or after giving effect to,
the foregoing. 

        SECTION 7.2.8    Restrictive Agreements.    The Borrower shall not, and shall not permit any Subsidiary to,
enter into any agreement (excluding any Loan Document and any agreement governing any Indebtedness permitted by clause (e) of  Section 7.2.1 as to
the assets financed with the proceeds of such Indebtedness): 

        (a)   expressly
restricting the ability of the Borrower or such Subsidiary to amend or otherwise modify any Loan Document; 

        (b)   restricting
the ability of any Affiliate of the Borrower to make any payments, directly or indirectly, to the Borrower by way of dividends or make distributions on its
capital stock or member or other ownership interests or to pay any Indebtedness owed to the Borrower; or 

        (c)   restricting
the ability of the Borrower or such Subsidiary to make loans or advances to the Borrower or any other Subsidiary. 

        SECTION 7.2.9    Limitation on Lines of Business.    The Borrower shall not, and shall not permit any
Subsidiary to, change its legal form or Organic Documents except as permitted by Section 7.2.3, change its Fiscal Year or engage in any business
other than the construction, ownership, maintenance and operation of the Facilities, the sale of wholesale electric power therefrom and related products and services and such other business as may be
reasonably incidental thereto. 

        SECTION 7.2.10    Swap Agreements.    The Borrower shall not, and shall not permit any Subsidiary to, enter
into any Swap Agreement, except, in the case of the Borrower, (a) Interest Rate Hedging Agreements, (b) Commodity Hedge and Power Sales Agreements, (c) Eligible Commodity Hedge
and Power Sale Agreements, provided that the aggregate amount of Capacity to be provided pursuant to Eligible Commodity Hedge and Power Sale Agreements
having terms in excess of one year for periods thereof commencing on such one-year date shall not exceed the projected available Capacity of all the Facilities and (d) other Swap
Agreements in the ordinary course of business and not for speculative purposes; provided that, in the case of  clauses (b), (c) and (d) above, the
aggregate amount of Capacity to be provided pursuant to such Swap Agreements shall not exceed (on a net basis) the projected available Capacity of all the Facilities. 

        SECTION 7.2.11    Amendment, Modification or Waiver of Certain Documents.    The Borrower shall not agree or
consent to any termination, amendment, modification or waiver of (a) Section 18.19 of each of the Powerton/Joliet Lease Participation
Agreements, (b) the definition of "Free Cashflow" set forth in the Powerton/Joliet Lease Operative Documents, (c) the Powerton/Joliet Lease Intercompany Notes or (d) or any other
provision of the Powerton/Joliet Lease Operative Documents that increases or is reasonably likely to increase the liability, or the obligations, of the Borrower (or decreases or is 

Third Amended and Restated Credit Agreement

62

 

reasonably
likely to decrease the liability, or the obligations, of EME) with respect to the Powerton/Joliet Lease Operative Documents in any material respect. 

        SECTION 7.2.12    Specified Transaction.    The Borrower shall not, and shall not permit any Subsidiary to,
directly or indirectly enter into any Specified Transaction. 

ARTICLE
VIII 

EVENTS
OF DEFAULT 

        SECTION 8.1    Listing of Events of Default.    Each of the following events or occurrences described in this  Section 8.1 shall constitute an "Event of Default". 

        SECTION 8.1.1    Non-Payment of Obligations.    The Borrower shall default in (a) the
payment of any principal of any Loan or any reimbursement obligation in respect of any LC Exposure or the Borrower shall fail to Cash Collateralize its LC Exposure when due or
(b) the payment of interest on any Loan or LC Exposure, any fees pursuant to Section 3.3 or any other Obligations under the
Loan Documents, within five (5) Business Days after any such interest or other amount becomes due in accordance with the terms thereof or hereof. 

        SECTION 8.1.2    Breach of Warranty.    Any representation or warranty of the Borrower, any of its
Subsidiaries, EMMT or any Midwest Related Party made or deemed to be restated or remade in any Loan Document to which it is a party or any other writing or certificate furnished by or on behalf of the
Borrower, such Subsidiary, EMMT or such Midwest Related Party to the Administrative Agent, the Collateral Trustee or any Lender for the purposes of or in connection with any such Loan Document
(including any certificates delivered pursuant to Article V) is or shall be incorrect when made or deemed made in any material respect. 

        SECTION 8.1.3    Non-Performance of Certain Covenants and Obligations.    The Borrower shall
default in the due performance and observance of any of its obligations under Section 7.1.1(e)(i),  7.1.2, 7.1.5 (solely with respect to the Mortgaged Facilities),  7.1.9 or 7.2. 

        SECTION 8.1.4    Non-Performance of Other Covenants and Obligations.    The Borrower, any of its
Subsidiaries, EMMT or any Midwest Related Party shall default in the due performance and observance of any other covenant or agreement contained in any Loan Document to which it is a party, and such
default shall continue unremedied for a period of thirty (30) days after written notice thereof shall have been given to the Borrower by the Administrative Agent. 

        SECTION 8.1.5    Default on other Indebtedness; Payment Default under EMMT Agreements.

        (a)   A
default shall occur in the payment when due (subject to any applicable grace period), whether by acceleration or otherwise, of (i) any Indebtedness
(other than Indebtedness described in Section 8.1.1,Powerton/Joliet Lease Liabilities and
Indebtedness described in clause (g) of the definition of "Indebtedness" herein) of the Borrower, any of its Subsidiaries or any Midwest Related Party or (ii) any EMMT Indebtedness, in
either case, having a principal amount, individually or in the aggregate, of at least $40,000,000, or a default shall occur in the performance or observance of any obligation or condition with respect
to such Indebtedness or EMMT Indebtedness, as applicable, if the effect of such default is to accelerate the maturity of any such Indebtedness or EMMT Indebtedness, as applicable, or such default
shall continue unremedied for any applicable period of time sufficient to permit the holder or holders of such Indebtedness or EMMT Indebtedness, as applicable, or any trustee or agent for such
holders, to cause such Indebtedness or EMMT Indebtedness, as applicable, to become due and payable prior to its expressed maturity. 

Third Amended and Restated Credit Agreement

63

 

        (b)   A
default shall occur in the payment or reimbursement when due by EMMT of any amount in excess of $2,000,000 owed to the Borrower under any Energy Management Agreement
and such default shall continue unremedied for a period of thirty (30) days. Notwithstanding the foregoing, any such failure to pay or reimburse the Borrower shall not constitute a default
(and such period of thirty (30) days shall not begin to toll) for purposes of this clause (b) until EMMT shall have received the
corresponding payment or reimbursement from the counterparty under the applicable Back-to-Back Transaction; provided, that
(i) EMMT shall have used commercially reasonable efforts to obtain payment from such counterparty, (ii) such counterparty was, at the time such Back-to-Back
Transaction was entered into, Investment Grade and (iii) to the extent of any offsets between EMMT and such counterparty (unrelated to Back-to-Back Transactions with the
Borrower) that reduce such counterparty's obligation to make payment to EMMT with respect to such Back-to-Back Transaction, EMMT shall be required to make payment to the
Borrower in the amount of such offset or reduction. 

        (c)   A
default shall occur in the payment when due by EMMT of any amount in excess of $2,000,000 owed to EME under an EME Trading Revolver and EME shall have commenced
remedies to enforce payment thereunder and such default shall continue unremedied for a period of thirty (30) days. 

        (d)   The
Borrower or any of its Subsidiaries shall default on any required payment obligation under any Swap Agreement in excess of $40,000,000, individually or in the
aggregate for the Borrower and its Subsidiaries, after giving effect to any grace periods, dispute resolution provisions or other similar provisions contained in such Swap Agreement (it being
acknowledged and agreed that any such Event of Default shall be deemed to be cured for all purposes under the Loan Documents if and when such Person pays or causes the payment of such defaulted amount
and so long as after such payment is made, no "Termination Event" or similar event exists under such Swap Agreement). 

        SECTION 8.1.6    Bankruptcy, Insolvency.    The Borrower, any of its Subsidiaries, EMMT, any Midwest Related
Party or EME shall: 

        (a)   become
insolvent or generally fail to pay, or admit in writing its inability or unwillingness to pay, debts as they become due; 

        (b)   apply
for, consent to, or acquiesce in, the appointment of a trustee, receiver, sequestration or other custodian for itself or a substantial portion of a its property,
or make a general assignment for the benefit of creditors; 

        (c)   in
the absence of such application, consent or acquiescence, permit or suffer to exist the appointment of a trustee, receiver, sequestration or other custodian for
itself or for a substantial part of its property, and such trustee, receiver, sequestration or other custodian shall not be discharged within sixty (60) days,  provided that nothing in the Loan
Documents shall prohibit or restrict any right the Administrative Agent, the Collateral Trustee or any Lender may have
under applicable law to appear in any court conducting any relevant proceeding during such sixty (60) day period to preserve, protect and defend its rights under the Loan Documents
(and the Borrower shall not object to any such appearance); 

        (d)   permit
or suffer to exist the commencement of any bankruptcy, reorganization, debt arrangement or other case or proceeding under any bankruptcy or insolvency law, or any
dissolution, winding up or liquidation proceeding, and, if any such case or proceeding is not commenced by the Borrower, such case or proceeding shall be consented to or acquiesced in by the Borrower
or shall result in the entry of an order for relief or shall remain for sixty (60) days undismissed, provided that nothing in the Loan Documents
shall prohibit or restrict any right the 

Third Amended and Restated Credit Agreement

64

 

Administrative
Agent, Collateral Trustee or any Lender may have under applicable law to appear in any court conducting any such case or proceeding during such sixty (60) day period to preserve,
protect and defend its rights under the Loan Documents (and the Borrower shall not object to any such appearance); or 

        (e)   take
any corporate action authorizing, or in furtherance of, any of the foregoing. 

        SECTION 8.1.7    Pension Plans.    Any of the following events shall occur with respect to any
Pension Plan: 

        (a)   the
institution of any steps by the Borrower, any member of the Controlled Group or any other Person to terminate a Pension Plan or the occurrence of any other event or
condition with respect to any Pension Plan, Welfare Plan or Multiemployer Plan if, as a result of such termination or such other event or condition, together with all other such terminations, events
or conditions, if any, the Borrower or any Controlled Group member could reasonably expect to incur, individually or in the aggregate, a liability or obligation in excess of $40,000,000; or 

        (b)   a
contribution failure occurs with respect to any Pension Plan sufficient to give rise to a Lien under Section 302(f) of ERISA or Section 412 of
the Code. 

        SECTION 8.1.8    Judgments.    Any judgment or order for the payment of money in excess of $40,000,000
individually or in the aggregate (taking into account any insurance proceeds payable under a policy where the insurer has accepted coverage without reservation) shall be rendered against Borrower and
such judgments or decrees shall not have been vacated, discharged or effectively stayed or bonded within sixty (60) days from the entry thereof. 

        SECTION 8.1.9    Regulatory Violation.    Any Regulatory Violation shall have occurred and
be continuing. 

        SECTION 8.1.10    Loan Documentation.    Except as provided in or permitted by  Section 9.10(c), this Agreement or any Loan Document is declared unenforceable or
is terminated or any Lien securing Indebtedness under this
Agreement purported to be created by any Security Document shall at any time fail to constitute a valid and first priority, perfected Lien on the Collateral intended to be covered thereby in favor of
the Collateral Trustee, free and clear of all other Liens (other than Permitted Liens), or the Borrower, any of its Subsidiaries, EMMT or any Midwest Related Party shall assert that such Lien is not a
valid and first priority, perfected Lien or any of the Security Documents to which it is a party shall no longer be in full force and effect. 

        SECTION 8.1.11    Change-In-Control.    Any Change-In-Control
shall have occurred and be continuing. 

        SECTION 8.1.12    Powerton/Joliet Leases.    Any of the Powerton/Joliet Lease Trusts (or the related
Lease Indenture Trustee) (under, and as defined in the related, Powerton/Joliet Lease Operative Documents) shall have commenced to exercise remedies in accordance with  Section 17 of each of the
Powerton/Joliet Leases to terminate any of the Powerton/Joliet Leases and repossess any of the Powerton/Joliet
Lease Assets. 

        SECTION 8.1.13    EME Obligations.    EME shall fail to make payment or fail to perform its obligations under
any Powerton/Joliet Lease Guarantee or any Powerton/Joliet Lease Intercompany Note within five (5) Business Days after any such payment becomes due in accordance with the terms thereof
or hereof. 

        SECTION 8.1.14    Powerton/Joliet Documentation.    Any of the Powerton/Joliet Lease Guarantees or the
Powerton/Joliet Lease Intercompany Notes is declared unenforceable or is terminated, or EME 

Third Amended and Restated Credit Agreement

65

 

or
any Powerton/Joliet Trust shall assert that any of the Powerton/Joliet Lease Guarantees or the Powerton/Joliet Intercompany Notes to which it is a party shall no longer be in full force
and effect. 

        SECTION 8.1.15    EME Default.    Any one of the following shall occur with respect to Indebtedness of EME
having a principal amount, individually or in the aggregate, in excess of $40,000,000: 

        (a)   a
default shall occur in the payment when due (subject to any applicable grace period), whether by acceleration or otherwise, of such Indebtedness of EME; or 

        (b)   a
default shall occur in the performance or observance of any obligation or condition with respect to Indebtedness if the effect of such default is to accelerate the
maturity of any such Indebtedness. 

        SECTION 8.2    Action if Bankruptcy.    If any Event of Default described in  clauses (a) through (e) of
 Section 8.1.6 shall have occurred and be continuing with respect to the Borrower, the Commitments (if not theretofore terminated) shall
automatically terminate and the outstanding principal amount of all outstanding Loans and all other monetary Obligations under the Loan Documents shall automatically be and become immediately due and
payable, without notice or demand. 

        SECTION 8.3    Action if Other Event of Default.    If any Event of Default (other than any Event of Default
described in clauses (a) through (e) of  Section 8.1.6 with respect to the Borrower) shall
occur for any reason, whether voluntary or involuntary, and be continuing, the Administrative
Agent, upon the direction of the Required Lenders, shall by written notice to the Borrower declare all or any portion of the outstanding principal amount of the Loans and other monetary Obligations
under the Loan Documents to be due and payable and/or the Commitments (if not theretofore terminated) to be terminated, whereupon the full unpaid amount of such Loans and other monetary
Obligations under the Loan Documents which shall be so declared due and payable shall be and become immediately due and payable, without further notice, demand or presentment, and/or, as the case may
be, the Commitments shall terminate. The rights provided for in the Loan Documents are cumulative and are not exclusive of any other rights, powers, privileges or remedies provided by law or in
equity, or under any other instrument, document or agreement now existing or hereafter arising. 

        SECTION 8.4    Rescission of Declaration.    Any declaration made pursuant to  Section 8.3 may, should the Required Lenders in their sole and absolute
discretion so elect, be rescinded by written notice to the
Borrower at any time after the principal of the Loans shall have become due and payable, but before any judgment or decree for the payment of the monies so due, or any part thereof, shall have been
entered; provided that the Borrower shall have paid all arrears of interest upon the Loans and all other amounts then owed to the Administrative Agent
and the Lenders including all costs, expenses and liabilities incurred by the Administrative Agent and the Lenders in respect of such declaration and all consequences thereof (except the principal of
the Loans which by such declaration shall have become payable) and every other Event of Default shall have been made good, waived or cured; provided
that no such rescission or annulment shall extend to or affect any subsequent Event of Default or impair any right consequent thereon. 

ARTICLE
IX 

THE
ADMINISTRATIVE AGENT 

        SECTION 9.1    Actions.

        (a)   Each
Lender and each Issuing Lender hereby appoints JPMCB as its Administrative Agent under and for purposes of each Loan Document. Each Lender and each Issuing Lender
authorizes the Administrative Agent to act on its behalf under each Loan Document and, in the 

Third Amended and Restated Credit Agreement

66

 

absence
of other written instructions from the Required Lenders received from time to time by the Administrative Agent (with respect to which the Administrative Agent agrees that it will comply,
except as otherwise provided in this Section or as otherwise advised by counsel), to exercise such powers hereunder and thereunder as are specifically delegated to or required of the Administrative
Agent by the terms hereof and thereof, together with such powers as may be reasonably incidental thereto. Notwithstanding any provision to the contrary contained elsewhere in any Loan Document, the
Administrative Agent shall not have any duties or responsibilities, except those expressly set forth herein, nor shall the Administrative Agent have or be deemed to have any fiduciary relationship
with any Issuing Lender or any Lender, and no implied covenants, functions, responsibilities, duties, obligations or liabilities shall be read into any Loan Document or otherwise exist against the
Administrative Agent. Without limiting the generality of the foregoing sentence, the use of the term "agent" in this Agreement with reference to the Administrative Agent is not intended to connote any
fiduciary or other implied (or express) obligations arising under agency doctrine of any applicable law. Instead, such term is used merely as a matter of market custom, and is intended to
create or reflect only an administrative relationship between independent contracting parties. 

        (b)   Each
Lender hereby agrees to indemnify (which indemnity shall survive any termination of this Agreement) the Agent-Related Persons  pro rata according to such Lender's Percentage, from and against any
and all liabilities, obligations, losses, damages, claims, costs or expenses
of any kind or
nature whatsoever which may at any time be imposed on, incurred by, or asserted against, the Agent-Related Persons in any way relating to or arising out of any Loan Document, including reasonable
attorneys' fees, and as to which the Administrative Agent is not reimbursed by the Borrower; provided,  however, that no Lender shall be liable for the
payment of any portion of such liabilities, obligations, losses, damages, claims, costs or expenses
which are determined by a court of competent jurisdiction in a final proceeding to have resulted from the Agent-Related Person's gross negligence or willful misconduct. No Agent-Related Persons shall
be required to take any action under any Loan Document, or to prosecute or defend any suit in respect of or any Loan Document, unless it is indemnified hereunder to its satisfaction. If any indemnity
in favor of the Administrative Agent shall be or become, in its determination, inadequate, the Agent-Related Person may call for additional indemnification from the Lenders and cease to do the acts
indemnified against hereunder until such additional indemnity is given. 

        SECTION 9.2    Funding Reliance.    Unless the Administrative Agent shall have been notified by telephone,
confirmed in writing, by any Lender by 12:00 Noon, New York City time, on the Business Day prior to the Closing Date that such Lender will not make available the amount which would
constitute its Percentage of the Borrowing on the Closing Date, the Administrative Agent may assume that such Lender has made such amount available to the Administrative Agent and, in reliance upon
such assumption, may, but shall not be required to, make available to the Borrower a corresponding amount. If and to the extent that such Lender shall not have made such amount available to the
Administrative Agent, such Lender and the Borrower severally agree to repay the Administrative Agent forthwith on demand such corresponding amount together with interest thereon, for each day from the
date the Administrative Agent made such amount available to the Borrower to the date such amount is repaid to the Administrative Agent, at the interest rate applicable at the time to Loans comprising
such Borrowing; provided, that if such Lender makes available the amount which is its Percentage of the Borrowing on or before the next Business Day
following the day when due, the interest rate payable on such amount shall be the Federal Funds Effective Rate. 

        SECTION 9.3    Exculpation.    No Agent-Related Person shall be liable to any Lender for any action taken or
omitted to be taken by it under any Loan Document, or in connection therewith, except for its own willful misconduct or gross negligence, nor responsible for any recitals or warranties 

Third Amended and Restated Credit Agreement

67

 

herein
or therein, nor for the effectiveness, enforceability, validity or due execution of any Loan Document, nor to make any inquiry respecting the performance by the Borrower of its obligations
under any Loan Document. Any such inquiry which may be made by the Administrative Agent shall not obligate it to make any further inquiry or to take any action. Each Agent-Related Person shall be
entitled to rely upon advice of counsel concerning legal matters and upon any notice, consent, certificate, statement or writing which the Administrative Agent believes to be genuine and to have been
presented by a proper Person. 

        SECTION 9.4    Successor.    The Administrative Agent may resign as such at any time upon at least thirty
(30) days' prior notice to the Borrower, all Lenders and all Issuing Lenders. If the Administrative Agent at any time shall resign, the Required Lenders may, within ten (10) days after
such notice and with the consent of the Borrower (not to be unreasonably withheld), appoint another Lender as a successor
Administrative Agent which shall thereupon become the Administrative Agent hereunder. If no successor Administrative Agent shall have been so appointed by the Required Lenders, and shall have accepted
such appointment, within thirty (30) days after the retiring Administrative Agent's giving notice of resignation, then the retiring Administrative Agent may, on behalf of the Lenders, after
notice to and consultation with the Borrower, appoint a successor Administrative Agent, which shall be one of the Lenders or an Assignee, and shall have a combined capital and surplus of at least
$250,000,000. Upon the acceptance of any appointment as Administrative Agent hereunder by a successor Administrative Agent, such successor Administrative Agent shall be entitled to receive from the
retiring Administrative Agent such documents of transfer and assignment as such successor Administrative Agent may reasonably request, and shall thereupon succeed to and become vested with all rights,
powers, privileges and duties of the retiring Administrative Agent, and the retiring Administrative Agent shall be discharged from its duties and obligations under this Agreement. After the effective
date of any retiring Administrative Agent's resignation hereunder as the Administrative Agent, the provisions of (a) this Article IX shall
inure to its benefit as to any actions taken or omitted to be taken by it while it was the Administrative Agent under this Agreement; and
(b) Section 10.3 and Section 10.4 shall continue to inure to its benefit. 

        SECTION 9.5    Loans by JPMCB.    JPMCB shall have the same rights and powers with respect to the Loans made by
it or any of its Affiliates as any other Lender and may exercise the same as if it were not the Administrative Agent. JPMCB and its Affiliates may accept deposits from, lend money to, and generally
engage in any kind of business with the Borrower or any Subsidiary or Affiliate of the Borrower as if JPMCB were not the Administrative Agent hereunder. 

        SECTION 9.6    Reliance by Administrative Agent.

        (a)   The
Administrative Agent shall be entitled to rely, and shall be fully protected in relying, upon any writing, resolution, notice, consent, certificate, affidavit,
letter, telegram, facsimile, telex or telephone message, statement or other document or conversation believed by it to be genuine and correct and to have been signed, sent or made by the proper Person
or Persons, and upon advice and statements of legal counsel (including counsel to the Borrower or any of its Affiliates), independent accountants and other experts selected by the Administrative
Agent. The Administrative Agent shall be fully justified in failing or refusing to take any action under any Loan Document unless it shall first receive such advice or concurrence of the Required
Lenders as it deems appropriate and, if it so requests, it shall first be indemnified to its satisfaction by the Lenders against any and all liability and expense which may be incurred by it by reason
of taking or continuing to take any such action. The Administrative Agent shall in all cases be fully protected in acting, or in refraining from acting, under any Loan Document in accordance with a
request or consent of the Required Lenders and such request and any action taken or failure to act pursuant thereto shall be binding upon all of the Lenders. 

Third Amended and Restated Credit Agreement

68

 

        (b)   For
purposes of determining compliance with the conditions specified in Section 5.1, each Lender that has executed
this Agreement shall be deemed to have consented to, approved or accepted or to be
satisfied with, each document or other matter either sent by the Administrative Agent to such Lender for consent, approval, acceptance or satisfaction, or required thereunder to be consented to or
approved by or acceptable or satisfactory to the Lender. 

        SECTION 9.7    Notice of Default.    The Administrative Agent shall not be deemed to have knowledge or notice
of the occurrence of any Default or Event of Default, except with respect to defaults in the payment of principal, interest and fees required to be paid to the Administrative Agent for the account of
the Lenders, unless the Administrative Agent shall have received written notice from a Lender or the Borrower referring to this Agreement, describing such Default or Event of Default and stating that
such notice is a "notice of default". The Administrative Agent will notify the Lenders of its receipt of any such notice. The Administrative Agent shall take such action with respect to such Default
or Event of Default as may be requested by the Required Lenders in accordance with Article VIII;  provided, however, that unless and until the Administrative Agent has received any such request, the
Administrative Agent may (but shall not be obligated to) take such action, or refrain from taking such action, with respect to such Default or Event of Default as it shall deem advisable or in
the best interest of the Lenders. 

        SECTION 9.8    Credit Decisions.    Each Lender acknowledges that it has, independently of the Agent-Related
Person and each other Lender, and based on such Lender's review of the financial information of the Borrower, the Loan Documents (the terms and provisions of which being satisfactory to such
Lender) and such other documents, information and investigations as such Lender has deemed appropriate, made its own credit decision to extend its Commitments. Each Lender also acknowledges that it
will, independently of the Administrative Agent and each other Lender, and based on such other documents, information and investigations as it shall deem appropriate at any time, continue to make its
own credit decisions as to exercising or not exercising from time to time any rights and privileges available to it under any Loan Document. 

        SECTION 9.9    Copies.    The Administrative Agent shall give prompt notice to each Lender of each notice or
request required or permitted to be given to the Administrative Agent by the Borrower pursuant to the terms of this Agreement (unless concurrently delivered to the Lenders by the Borrower). The
Administrative Agent will distribute to each Lender each document or instrument (including each document or instrument delivered by the Borrower to the Administrative Agent pursuant to  Articles V
and VII) received for its account and copies of all other communications
received by the Administrative Agent from the Borrower for distribution to the Lenders by the Administrative Agent in accordance with the terms of this Agreement. 

        SECTION 9.10    Collateral.

        (a)   Each
Lender hereby acknowledges and agrees that (i) such Lender's right or interest in the Collateral (or any portion thereof) shall be subject to the
terms of the Collateral Trust Agreement and the other Security Documents, including the requisite level of consent by holders of Priority Lien Debt to enforce upon the Collateral and (ii) this
acknowledgement and agreement constitutes a Priority Debt Sharing Confirmation (as defined in the Collateral Trust Agreement). 

        (b)   The
Borrower hereby acknowledges, agrees and confirms that each Lender and the Administrative Agent are entitled to the benefit of the Collateral Trust Agreement and all
of the benefits of a Priority Lien Secured Party and the Priority Liens created under (and as defined in) the Collateral Trust Agreement and the other Security Documents. 

Third Amended and Restated Credit Agreement

69

 

        (c)   If
on any date following the Closing Date: 

        (i)    the
Debt Ratings by at least two of the following Rating Agencies are at least Baa3 or better by Moody's, BBB- or better by S&P and BBB- and/or
better by Fitch; 

        (ii)   no
Default or Event of Default shall have occurred and then be continuing; 

then,
beginning on that day, the provisions of Section 7.1.8 shall be terminated and rendered void and of no further force and effect, the
Collateral Trustee's Lien on the Collateral shall be automatically released, and each Security Document shall be terminated and rendered void and of no further force and effect, except for terms
thereof expressly stated therein to survive such termination; provided that each other Secured Party (other than the Secured Parties party to this
Agreement in such capacity) shall have indefeasibly released (whether prior to such day or contemporaneously upon such day) its Lien on the Collateral. 

ARTICLE
X 

MISCELLANEOUS
PROVISIONS 

        SECTION 10.1  Waivers, Amendments.

        (a)   The
provisions of each Loan Document may from time to time be amended, modified or waived, if such amendment, modification or waiver is in writing and consented to by
the Borrower and the Required Lenders; provided, however, that no such amendment, modification or waiver
shall (i) forgive or reduce the principal amount or extend any payment of principal pursuant to Section 3.1(a) or the final
scheduled date of maturity of any Loan or LC Disbursement, reduce the stated rate of any interest or
fee payable hereunder or extend the scheduled date of any payment thereof, or increase the amount or extend the expiration date of any Lender's Commitment without the consent of each Lender directly
affected thereby; (ii) amend, modify or waive any provision of this Section 10.1 or any percentage specified in the definition of
"Required Lenders", or consent to the assignment or transfer by the Borrower of any of its rights and obligations under the Loan Documents, in each case without the written consent of all Lenders;
(iii) amend, modify or waive any pro rata provision of Section 4.8
or 4.9, or any provision in the Loan Documents which provides for amounts paid in respect of the Obligations to be shared among the Lenders
ratably, without the consent of all Lenders; (iv) except as provided in Section 9.10, provide for any material release of
Collateral without the consent of all Lenders; or (v) affect the interests, rights or obligations of the Administrative Agent qua the
Administrative Agent or the Issuing Lenders qua the Issuing Lenders shall be made without consent of the Administrative Agent or the Issuing Lenders, as
the case may be. Any such waiver and any such amendment, supplement or modification shall apply equally to each of the Lenders and shall be binding upon the Borrower, the Lenders, the Administrative
Agent, the Issuing Lenders and all future holders of the Loans. In the case of any waiver, the Borrower and its Subsidiaries, the Lenders and the Administrative Agent shall be restored to their former
position and rights and under the Loan Documents, and any Default or Event of Default waived shall be deemed to be cured and not continuing; but no such waiver shall extend to any subsequent or other
Default or Event of Default, or impair any right consequent thereon. 

        (b)   No
failure or delay by the Administrative Agent, any Issuing Lender or any Lender in exercising any power or right under any Loan Document shall operate as a waiver
thereof, nor shall any single or partial exercise of any such power or right, or any abandonment or discontinuance of steps to enforce such power or right, preclude any other or further exercise
thereof or the exercise of any other power or right. The rights and remedies of the Administrative Agent, the Issuing Lenders and the Lenders hereunder are cumulative and are not exclusive of any 

Third Amended and Restated Credit Agreement

70

 

rights
or remedies they would otherwise have. No notice to or demand on the Borrower in any case shall entitle it to any notice or demand in similar or other circumstances. No waiver or approval by
the Administrative Agent, any Issuing Lender, or any Lender under any Loan Document shall, in any event, be effective unless the same is permitted by  paragraph (a) of this Section 10.1, and shall, except as may be otherwise stated in such
waiver or approval, be applicable to subsequent transactions. No waiver or approval hereunder shall require any similar or dissimilar waiver or approval thereafter to be granted hereunder. 

        SECTION 10.2    Notices.    All notices and other communications provided to any party hereto under any Loan
Document shall be in writing or by facsimile and addressed, delivered or transmitted to such party at its address or facsimile number set forth on the signature pages hereof or  Schedule 1.1(a)
or set forth in the Administrative Questionnaire of such party or the Assignment Agreement or at such other address or
facsimile number as may be designated by such party in a written notice to the other parties. Any notice, if mailed and properly addressed with postage prepaid shall be effective five
(5) Business Days after being sent or if properly addressed and sent by pre-paid courier service, shall be deemed given when received; any notice, if transmitted by facsimile, shall
be deemed given when transmitted (if confirmed). Each Lender acknowledges and accepts the terms of the Communications Agreement and agrees that Communications (as defined in the
Communications Agreement) may be made available to such Lender as provided in the Communications Agreement. 

        SECTION 10.3    Payment of Costs and Expenses.

        (a)   The
Borrower agrees to pay promptly on demand all reasonable out-of-pocket costs and expenses of JPMCB, the Administrative Agent and the Issuing
Lenders and their respective Affiliates (including the reasonable fees and out-of-pocket costs and expenses of special New York counsel and relevant local counsel to the
Administrative Agent) in connection with: 

        (i)    the
negotiation, preparation, execution, delivery and administration of each Loan Document, including schedules and exhibits, and any amendments, waivers, consents,
supplements or other modifications to any Loan Document as may from time to time hereafter be required; 

        (ii)   the
preparation and review of the form of any document or instrument relevant to any Loan Document; provided,  however, that the Borrower shall have no
obligation to pay for the cost of the documentation of assignments or participations as provided in  Section 10.11 (unless such assignment is made pursuant to Section 4.11); and 

        (iii)  in
the case of the Issuing Lenders, all out-of-pocket expenses incurred by the any Issuing Lender in connection with the Issuance of any Letter
of Credit or any demand for payment thereunder; 

in
each case, upon presentation of statement of account in reasonable detail, whether or not the transactions contemplated hereby are consummated. 

        (b)   Without
duplication of the Borrower's obligations under Section 4.7, the Borrower further agrees to pay upon
demand, and to save the Administrative Agent, the Issuing Lenders and the Lenders harmless from all liability for all costs, expenses, assessments, or other charges, and any stamp or other similar
Taxes which may be payable in connection with the execution, delivery or enforcement of any Loan Document, the Loans or Letter of Credit hereunder or any filing, registration, recording or perfection
of any security interest contemplated by any Security Document. The Borrower also agrees to reimburse the Administrative Agent, each Issuing Lender and each Lender, as applicable, promptly upon demand
upon presentation of a statement of account in reasonable detail for (i) all reasonable out-of-pocket costs and expenses (including fees and
out-of-pocket expenses of counsel) incurred by the Administrative Agent, each Issuing Lender 

Third Amended and Restated Credit Agreement

71

 

and
each Lender in connection with the enforcement or protection of the rights in connection with this Agreement and the other Loan Documents, including its rights under this Section and including the
negotiation of any restructuring or work-out, whether or not consummated, of any Obligations under the Loan Documents and (ii) all out-of-pocket costs and
expenses (including fees and out-of-pocket costs and expenses of counsel) by the Administrative Agent, each Issuing Lender and each Lender in connection with the enforcement of
any Obligations under the Loan Documents after an Event of Default or in connection with any insolvency proceedings; provided that, in either case, the
Borrower shall not be obligated to reimburse such costs and expenses that are found in a final judgment by a court of competent jurisdiction to have been incurred in an attempt to enforce such rights
and remedies that were pursued by such Administrative Agent or Lender in bad faith and without any reasonable basis in fact or law. 

        SECTION 10.4    Indemnification.

        (a)   In
consideration of the execution and delivery of this Agreement by each Lender and the extension of the Commitments and the Loans, the Borrower hereby indemnifies,
exonerates and holds the Administrative Agent, JPMCB, each Titled Institution, each Issuing Lender and each Lender and each of their respective Affiliates, officers, directors and employees
(collectively, the "Indemnified Parties") free and harmless from and against any and all losses, costs, actions, causes of action, suits, liabilities
and damages, and expenses incurred in connection therewith (irrespective of whether any such Indemnified Party is a party to the action for which indemnification hereunder is sought), including any
amounts paid to any Agent-Related Person pursuant to Section 9.1(b) and reasonable attorneys' fees and disbursements but excluding claims
for lost profits (collectively, the "Indemnified Liabilities"), joint or several, that may be incurred by or asserted or awarded against any Indemnified
Party, in each case arising out of or in connection with or relating to: 

        (i)    any
transaction financed or to be financed in whole or in part, directly or indirectly, with the proceeds of any Loan or Letter of Credit (including any refusal by any
Issuing Lender to honor a demand for payment under a Letter of Credit if the documents presented in connection with such demand do not strictly comply with the terms of such Letter of Credit; 

        (ii)   the
entering into and performance of any Loan Document by any of the Indemnified Parties (including any action brought by or on behalf of the Borrower as the result of
any determination by the Required Lenders pursuant to Article V not to fund any Loan); 

        (iii)  any
investigation, litigation, proceeding, or obligation related to any Environmental Law or other matter in any case arising out of the relationship of the parties
under this Agreement; or 

        (iv)  the
presence, or alleged presence, on or under, or the escape, seepage, leakage, spillage, discharge, emission or release from, any real property owned, leased or
operated by the Borrower or any of its Subsidiaries thereof of any Hazardous Material (including any losses, liabilities, damages, injuries, costs, expenses or claims asserted or arising under any
Environmental Law), or at any other locations regardless of whether caused by, or within the control of the Borrower, where such claim or liability arises out of the relationship of the parties under
this Agreement; 

whether
or not such investigation, litigation or proceeding is brought by the Borrower or its Affiliates, any of their respective shareholders or creditors, an Indemnified Party or any other person,
or an Indemnified Party is otherwise a party thereto and whether or not the transactions contemplated hereby are consummated, except for any such Indemnified Liabilities arising for the account of a
particular Indemnified Party by reason of the relevant Indemnified Party's (i) gross 

Third Amended and Restated Credit Agreement

72

 

negligence
or willful misconduct or (ii) breach of such Indemnified Party's obligations under this Agreement. If and to the extent that the foregoing undertaking may be unenforceable for any
reason, the Borrower hereby agrees to make the maximum contribution to the payment and satisfaction of each of the Indemnified Liabilities which is permissible under applicable law. 

        (b)   To
the extent permitted by applicable law, no Indemnified Party shall have any liability to the Borrower or its Affiliates or any of their respective shareholders or
creditors under any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of,
this Agreement or any agreement or instrument contemplated hereby, any Loan or the use of the proceeds thereof. 

        SECTION 10.5    Survival.    The obligations of the Borrower under  Sections 2.6.6, 4.3, 4.5,  4.6, 4.7, 10.3
and 10.4, and the obligations of the Lenders under Sections 9.1
and 2.6.6, shall in each case survive any termination of this Agreement, the payment in full of all Obligations under the Loan Documents and the
termination of all Commitments, and the obligations of the Borrower to the Retiring Lenders under the correlative provisions of such sections of the Existing Credit Agreement shall, in each case,
survive any termination of the Existing Credit Agreement, the payment in full of all Obligations under the Loan Documents and the Existing Credit Agreement and the termination of all Commitments. The
representations and warranties made by the Borrower in each Loan Document to which it is a party shall survive the execution and delivery of such Loan Document. 

        SECTION 10.6    Severability.    Any provision of any Loan Document which is prohibited or unenforceable in any
jurisdiction shall, as to such provision and such jurisdiction, be ineffective to the extent of such prohibition or unenforceability without invalidating the remaining provisions of such Loan Document
or affecting the validity or enforceability of such provision in any other jurisdiction. 

        SECTION 10.7    Headings.    The various headings and table of contents of each Loan Document are inserted for
convenience only and shall not affect the meaning, construction or interpretation of this Agreement or any other Loan Document or any provisions hereof or thereof. 

        SECTION 10.8    Execution in Counterparts.    This Agreement may be executed by the parties hereto in several
counterparts, each of which shall be executed by the Borrower and the Administrative Agent and be deemed to be an original and all of which shall constitute together but one and the
same agreement. 

        SECTION 10.9    Governing Law; Entire Agreement.    This Agreement, and the rights and obligations of the
parties under this Agreement, shall be governed by, and construed and interpreted in accordance with, the law of the state of New York. The Loan Documents represent the agreement of the
Borrower, the Administrative Agent, the Issuing Lenders and the Lenders and supersede any and all prior agreements and understandings, oral or written, relative or with respect to the subject matter
hereof, and there are no promises, undertakings, representations or warranties by the Administrative Agent, any Issuing Lender or any Lender relative to subject matter hereof not expressly set forth
or referred to in the Loan Documents. 

        SECTION 10.10    Successors and Assigns.    This Agreement shall be binding upon and shall inure to the benefit
of the parties hereto and their respective successors and assigns; provided, however, that: 

        (a)   the
Borrower may not assign or transfer its rights or obligations hereunder without the prior written consent of the Administrative Agent, all Issuing Lenders and all
Lenders; and 

        (b)   the
rights of sale, assignment and transfer of the Lenders are subject to Section 10.11. 

Third Amended and Restated Credit Agreement

73

   
        SECTION 10.11    Sale and Transfer of Loans; Participations in Loans.    Each Lender may assign, or sell
participations in, its Loans to one or more other Persons in accordance with this Section 10.11. 

        SECTION 10.11.1    Assignments.

        (a)   Any
Lender (an "Assignor") may, in accordance with applicable law, at any time and from time to time assign to any
Person (an "Assignee"), with the consent of (A) each Issuing Lender (B) the Administrative Agent and (C) the Borrower (such
consent not to be unreasonably withheld or delayed) (except that the consent of the Borrower shall not be required (x) in the case of any assignment to a Lender, an Affiliate of a Lender or an
Approved Fund of any Lender or (y) at any time a Default or Event of Default shall have occurred and be continuing or (z) on and after the date that a
Change-In-Control of the type referred to in clause (b) of the definition of "Change-In-Control" shall have occurred), all or any part of its
rights and obligations under this Agreement pursuant to an Assignment Agreement, executed by such Assignee, such Assignor and any other Person whose consent is required pursuant to this paragraph, and
delivered to the Administrative Agent for its acceptance and recording in the Register; provided that no such assignment to an Assignee (other than any
Lender or any Affiliate or Approved Fund thereof) shall be in an aggregate principal amount of less than $3,000,000 (other than, in each case, an assignment of all of a Lender's interests under this
Agreement and treating simultaneous assignments to and from Approved Funds of a single Lender as one assignment), unless otherwise agreed by the Borrower and the Administrative Agent and each Issuing
Lender; provided, further, that after giving effect to any such assignment the assigning Lender shall
have Loans or Commitments remaining of at least $3,000,000 in the aggregate amount (other than, in each case, an assignment of all of a Lender's interests under this Agreement and treating
simultaneous assignments to and from Approved Funds of a single Lender as one assignment). 

        Upon
such execution, delivery, acceptance and recording, from and after the effective date determined pursuant to such Assignment Agreement, (i) the Assignee thereunder shall be a
party hereto and, to the extent provided in such Assignment Agreement, have the rights and obligations of a Lender hereunder with Loans and Commitments as set forth therein, and (ii) the
Assignor thereunder shall, to the extent provided in such Assignment Agreement, be released from its obligations under this Agreement (and, in the case of an Assignment Agreement covering all of an
Assignor's rights and obligations under this Agreement, such Assignor shall cease to be a party hereto). Any assignment or sale that does not
comply with this clause (a) shall be treated for purposes of this Agreement as a sale by such Lender of a participation in such rights and
obligations in accordance with Section 10.11.2. 

        (b)   The
Administrative Agent shall, on behalf of the Borrower, maintain at its address referred to on Schedule 1.1(a)
a copy of each Accession Agreement delivered to it and a register (the "Register") for the recordation of the names and addresses of the Lenders
and the Commitment of, and the principal amount of the Loans owing to, each Lender from time to time. The entries in the Register shall be conclusive, in the absence of manifest error, and the
Borrower, the Administrative Agent, the Issuing Lenders and the Lenders shall treat each Person whose name is recorded in the Register as the owner of the Loans or the Commitments, as the case may be,
recorded therein for all purposes of this Agreement notwithstanding notice to the contrary. Any assignment of any Loan or any Commitment shall be effective only upon appropriate entries with respect
thereto being made in the Register. 

        (c)   Upon
its receipt of an Assignment Agreement executed by an Assignor, an Assignee and any other Person whose consent is required by  Section 10.11.1(a), together with payment to the Administrative Agent
of a registration and processing fee of $3,500 (unless waived by the 

Third Amended and Restated Credit Agreement

74

 

Administrative
Agent in its discretion and provided that only one such fee shall be payable in the case of simultaneous assignments to two or more
Approved Funds of a single Lender), the Administrative Agent shall (i) promptly accept such Assignment Agreement and (ii) record the information contained therein in the Register on the
effective date determined pursuant thereto. 

        (d)   For
avoidance of doubt, the parties to this Agreement acknowledge that the provisions of this Section 10.11.1
concerning assignments of Loans and Commitments relate only to absolute assignments and that such provisions do not prohibit assignments creating security interests, including any pledge or assignment
by a Lender of any Loan to any Federal Reserve Bank in accordance with applicable law; provided, that no such pledge or assignment of a security
interest shall release a Lender from any of its obligations hereunder or substitute any such assignee for such Lender as a party hereto. 

        (e)   Notwithstanding
anything to the contrary contained herein, any Lender (a "Granting Lender") may grant to a special
purpose funding vehicle (an "SPC"), identified as such in writing from time to time by the Granting Lender to the Administrative Agent and the
Borrower, the option to provide to the Borrower all or any part of any Loan that such Granting Lender would otherwise be obligated to make to the Borrower pursuant to this Agreement;  provided that
(i) nothing herein shall constitute a commitment by any SPC to make any Loan and (ii) if an SPC elects not to exercise such
option or otherwise fails to provide all or any part of such Loan, the Granting Lender shall be obligated to make such Loan pursuant to the terms hereof. The making of a Loan by an SPC hereunder shall
utilize the related Commitment of the Granting Lender to the same extent, and as if, such Loan were made by such Granting Lender. Each party hereto hereby agrees that no SPC shall be liable for any
indemnity or similar payment obligation under this Agreement (all liability for which shall remain with the Granting Lender). In furtherance of the foregoing, each party hereto hereby agrees
(which agreement shall survive the termination of this Agreement) that, prior to the date that is one year and one day
after the payment in full of all outstanding commercial paper or other senior indebtedness of any SPC, it will not institute against, or join any other person in instituting against, such SPC any
bankruptcy, reorganization, arrangement, insolvency or liquidation proceedings under the laws of the United States or any State thereof. In addition, notwithstanding anything to the contrary
contained in this Section 10.11.1, any SPC may (A) with notice to, but without the prior written consent of, the Borrower and the
Administrative Agent and without paying any processing fee therefor, assign all or a portion of its interests in any Loans to the Granting Lender or to any financial institutions (consented to by the
Borrower and Administrative Agent) providing liquidity and/or credit support to or for the account of such SPC to support the funding or maintenance of Loans and (B) disclose on a confidential
basis any non-public information relating to its Loans to any rating agency, commercial paper dealer or provider of any surety, guarantee or credit or liquidity enhancement to such SPC.
This Section 10.11.1(e) may not be amended without the written consent of each SPC. The Granting Lender, such SPC and any assignee of such SPC
shall comply with the requirements of Section 4.7 as Lender. 

        SECTION 10.11.2    Participations.    With notice to the Borrower and the Administrative Agent, any Lender may
at any time sell to one or more Persons (each of such Persons being herein called a "Participant") participating interests in any of the Loans,
Commitments or other interests of such Lender hereunder; provided, however, that: 

        (a)   no
participation contemplated in this Section 10.11.2 shall relieve such Lender from its Loans, Commitments and
other obligations under any Loan Document; 

Third Amended and Restated Credit Agreement

75

 

        (b)   such
Lender shall remain solely responsible for the performance of its Loans, Commitments and such other obligations; 

        (c)   the
Borrower, the Administrative Agent and the Issuing Lenders shall continue to deal solely and directly with such Lender in connection with such Lender's rights and
obligations under each of the Loan Documents; 

        (d)   no
Participant, unless such Participant is an Affiliate of such Lender, or is itself a Lender, shall be entitled to require such Lender to take or refrain from taking
any action under any Loan Document, except as provided in clause (f) of this  Section 10.11.2; 

        (e)   the
Borrower shall not be required to pay any amount under Sections 2.6.6,  4.3, 4.4, 4.5,  4.6, 4.7, 4.8,  4.9,
10.3 and 10.4, that is greater than the
amount which it would have been required to pay had no participating interest been sold; 

        (f)    in
no event shall any Participant under any such participation have any right to approve any amendment or waiver of any provision of any Loan Document, or any consent to
any departure by the Borrower therefrom, except to the extent that such amendment, waiver or consent would reduce the principal of, or interest on, the Loans or any fees payable hereunder, extend the
due date of such principal, interest or fee payments or increase the amount or extend the Commitment Termination Date of such Loans, in each case to the extent subject to such participation; 

        (g)   the
Borrower agrees that if amounts outstanding under this Agreement and the Loans are due or unpaid, or shall have been declared or shall have become due and payable
upon the occurrence of an Event of Default, each Participant shall, to the maximum extent permitted by applicable law, be deemed to have the right of setoff in respect of its participating interest in
amounts owing under this Agreement to the same extent as if the amount of its participating interest were owing directly to it as a Lender under this Agreement,  provided that, in purchasing such
participating interest, such Participant shall be deemed to have agreed to share with the Lenders the proceeds thereof
as provided in Section 4.10 as fully as if it were a Lender hereunder; 

        (h)   the
Borrower also agrees that each Participant shall be entitled to the benefits of Sections 4.3,  4.6 and 4.7 with respect to its participation in the Loans and the Commitments outstanding from
time to time as if it was a Lender; provided that, in the case of Section 4.7, such Participant
shall have complied with the requirements of said Section, as if it were a Lender and provided,  further,
that no Participant shall be entitled to receive any greater amount pursuant to any such Section than the transferor Lender would have been
entitled to receive in respect of the amount of the participation transferred by such transferor Lender to such Participant had no such transfer occurred; and 

        (i)    Notwithstanding
anything to the contrary in this Section 10.11.2, each Lender shall have the right to sell one or more participations in all or any part of its
Commitments, Loans or any other obligation to one or more lenders or other Persons that provide financing to such Lender in the form of sales and repurchases of participations without notice to the
Borrower and the Administrative Agent. 

        SECTION 10.12    Other Transactions.    Nothing contained herein shall preclude the Administrative Agent, any
Issuing Lender or any other Lender from engaging in any transaction, in addition to those contemplated by any Loan Document, with the Borrower or any of its Affiliates in which the Borrower or such
Affiliate is not restricted hereby from engaging with any other Person. 

Third Amended and Restated Credit Agreement

76

 

        SECTION 10.13    Submission To Jurisdiction; Waivers.    Each of the Borrower, the Administrative Agent, the
Issuing Lenders and the Lenders hereby irrevocably and unconditionally: 

        (a)   submits
for itself and its property in any legal action or proceeding relating to the Loan Documents to which it is a party, or for recognition and enforcement of any
judgment in respect thereof, to the non-exclusive general jurisdiction of the courts of the State of New York, the courts of the United States for the Southern District of
New York, and appellate courts from any thereof; 

        (b)   consents
that any such action or proceeding may be brought in such courts and waives any objection that it may now or hereafter have to the venue of any such action or
proceeding in any such court or that such action or proceeding was brought in an inconvenient court and agrees not to plead or claim the same; 

        (c)   agrees
that service of process in any such action or proceeding may be effected by mailing a copy thereof by registered or certified mail (or any substantially
similar form of mail), postage prepaid, to such Person at its address set forth on Schedule 1.1(a) or at such other address of which the
Administrative Agent shall have been notified pursuant to Section 10.2; 

        (d)   agrees
that nothing herein shall affect the right to effect service of process in any other manner permitted by law or shall limit the right to sue in any other
jurisdiction; and 

        (e)   waives,
to the maximum extent not prohibited by law, any right it may have to claim or recover in any legal action or proceeding referred to in this Section any special,
indirect, exemplary, punitive or consequential damages. 

        SECTION 10.14    WAIVERS OF JURY TRIAL.    EACH PARTY HERETO HEREBY WAIVES, TO THE
FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY RIGHT IT MAY HAVE TO A TRIAL BY JURY IN ANY LEGAL PROCEEDING DIRECTLY OR INDIRECTLY ARISING OUT OF OR RELATING TO THIS AGREEMENT OR THE TRANSACTIONS
CONTEMPLATED HEREBY (WHETHER BASED ON CONTRACT, TORT OR ANY OTHER THEORY). EACH PARTY HERETO (A) CERTIFIES THAT NO REPRESENTATIVE, AGENT OR ATTORNEY OF ANY OTHER PARTY HAS REPRESENTED,
EXPRESSLY OR OTHERWISE, THAT SUCH OTHER PARTY WOULD NOT, IN THE EVENT OF LITIGATION, SEEK TO ENFORCE THE FOREGOING WAIVER AND (B) ACKNOWLEDGES THAT IT AND THE OTHER PARTIES HERETO HAVE BEEN
INDUCED TO ENTER INTO THIS AGREEMENT BY, AMONG OTHER THINGS, THE MUTUAL WAIVERS AND CERTIFICATIONS IN THIS SECTION.

        SECTION 10.15    Non-Recourse Persons.    The Lenders acknowledge that no Non-Recourse
Person shall have any responsibility or liability for the Obligations under the Loan Documents. 

        SECTION 10.16    Acknowledgments.    The Borrower hereby acknowledges that: 

        (a)   it
has been advised by counsel in the negotiation, execution and delivery of the Loan Documents; 

        (b)   neither
the Administrative Agent, any Issuing Lender nor any Lender has any fiduciary relationship with or duty to the Borrower arising out of or in connection with any
of the Loan Documents, and the relationship between Administrative Agent, the Issuing Lenders and Lenders, on one hand, and the Borrower, on the other hand, in connection herewith or therewith is
solely that of debtor and creditor; and 

        (c)   no
joint venture is created by any of the Loan Documents or otherwise exists by virtue of the transactions contemplated hereby among the Lenders or among the Borrower
and the Lenders. 

Third Amended and Restated Credit Agreement

77

 

        SECTION 10.17    Confidentiality.    Each of the Administrative Agent, each Titled Institution, each Issuing
Lender and each Lender agrees to keep confidential all non-public information provided to it by the Borrower pursuant to this Agreement;  provided that nothing herein shall prevent the Administrative
Agent, any Titled Institution, any Issuing Lender or any Lender from disclosing any such
information (a) to the Administrative Agent, any Titled Institution, any Issuing Lender any other Lender or any Affiliate of any Lender, (b) to any transferee, prospective transferee or
any lender of a Lender that agrees to comply with the provisions at least as restrictive as those of this Section 10.17, (c) to its
employees, directors, agents, attorneys, accountants and other professional advisors or those of any of its Affiliates, (d) upon the request or demand of any Governmental Authority,
(e) in response to any order of any court or other Governmental Authority or as may otherwise be required pursuant to any Requirement of Law, (f) if requested or required to do so in
connection with any litigation or similar proceeding, (g) that has been publicly disclosed, (h) to the National Association of Insurance Commissioners or any similar organization or any
nationally recognized rating agency that requires access to information about a Lender's investment portfolio in connection with ratings issued with respect to such Lender, or (i) in connection
with the exercise of any remedy under any Loan Document. Notwithstanding anything herein to the contrary, the Borrower, Administrative Agent, each Titled Institution, each Issuing Lender and each
Lender (and their Affiliates and their respective partners, officers, directors, employees, accountants, attorneys and other advisors, agents and other representatives) may disclose to any and
all Persons, without limitation of any kind, any information with respect to the U.S. federal tax treatment and any facts that may be relevant to the U.S. federal tax structure of the
transactions contemplated hereby and all materials of any kind (including opinions and other tax analyses) that are provided to any of them relating to such treatment and tax structure;  provided,
however, that none of them shall disclose any other information, the disclosure of which is
otherwise limited, that is not relevant to understanding the U.S. federal tax treatment or U.S. federal tax structure of the transaction (including the identity of any party and
information that could lead another to determine the identity of any party), or any other information to the extent that such disclosure could result in a violation of any federal or state
securities law. 

        SECTION 10.18    USA PATRIOT Act.    Each Lender hereby notifies the Borrower and any guarantors of the Secured
Debt (as defined in the Collateral Trust Agreement) that pursuant to the requirements of the USA Patriot Act (Title III of Pub. L. 107-56 (signed into law October 26, 2001))
(the "Act"), it is required to obtain, verify and record information that identifies the Borrower and such guarantors, which information includes
the name and address of the Borrower and such guarantors and other information that will allow such Lender to identify the Borrower and such guarantors in accordance with the Act. 

        SECTION 10.19    EMMH Credit Agreement.    This Agreement constitutes a replacement of the Existing Credit
Agreement which constituted a replacement of the EMMH Credit Agreement as contemplated in clause (xv) of the general provisions of
Appendix A of each Powerton/Joliet Lease Participation Agreement and as such this Agreement constitutes the "Holdings Credit Agreement" for the purposes of the Powerton/Joliet Lease Operative
Documents. 

        SECTION 10.20    Retiring Lenders.    Each Retiring Lender shall, as of the Closing Date, cease to be a
"Lender" under (and, accordingly, shall cease to be a party to) the Existing Credit Agreement, and the Borrower hereby confirms and agrees that, as of the Closing Date, the Retiring Lenders shall have
no obligations or liabilities under this Agreement; provided, that the Retiring Lenders shall be entitled to the benefits of  Section 10.5. 

Third Amended and Restated Credit Agreement

78

   
        IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by their respective officers as of the day and year first above written. 

	 	 	MIDWEST GENERATION, LLC
	

 	
 	

By:	

/s/  STEVEN D. EISENBERG      
	 	 	 	
 Name: Steven D Eisenberg

Title:    Vice President
	

 	
 	

Address for Notices:
	

 	
 	

One Financial Place

440 South LaSalle Street, Suite 3500

Chicago, IL 60605

Telecopier No: (312) 583-6111
	

 	
 	

Taxpayer Identification Number: 33-0868558

Third Amended and Restated Credit Agreement

79

 

	 	 	JPMORGAN CHASE BANK, N.A.,

    as Administrative Agent
	

 	
 	

By:	

/s/  THOMAS CASEY      
	 	 	 	
 Name: Thomas Casey

Title:    Vice President
	

 	
 	

Address for Notices:
	

 	
 	

JPMorgan Chase Bank, N.A.

1111 Fannin

10th Floor

Houston, TX 77002

Attention: Ricardo Gonzales

Telecopier No: (713) 750 2228
	

 	
 	

With a copy to:
	

 	
 	

JPMorgan Chase Bank, N.A.

270 Park Avenue

4th Floor

New York, NY 10017-2014

Attention: Thomas L. Casey

Telecopier No.: (212)-270-3089

Third Amended and Restated Credit Agreement

80

 

	 	 	JPMORGAN CHASE BANK, N.A.,

    as Issuing Lender
	

 	
 	

By:	

/s/  THOMAS CASEY      
	 	 	 	
 Name: Thomas Casey

Title:    Vice President
	

 	
 	

Address for Notices:
	

 	
 	

JPMorgan Chase Bank, N.A.

270 Park Avenue

4th Floor

New York, NY 10017-2014

Attention: Thomas L. Casey

Telecopier No.: (212)-270-3089

Third Amended and Restated Credit Agreement

81

 

	 	 	CITICORP NORTH AMERICA, INC.,

    as Issuing Lender
	

 	
 	

By:	

/s/  NIETZSCHE RODRICKS      
	 	 	 	
 Name: Nietzsche Rodricks

Title:    Vice President
	

 	
 	

Address for Notices:
	

 	
 	

Citicorp North America, Inc.

2 Penns Way

Suite 110

New Castle, DE 19720

Attention: Diane Stewart

Telecopier No.: (212) 994-0847

Third Amended and Restated Credit Agreement

82

 

	 	 	UNION BANK OF CALIFORNIA, N.A.,

    as Lender
	

 	
 	

By:	

/s/  KEVIN M. ZITAR      
	 	 	 	
 Name: Kevin M. Zitar

Title:    Senior Vice President
	

 	
 	

Address for Notices:
	

 	
 	

Union Bank of California, N.A.

445 S. Figueroa Street

15th Floor

Los Angeles, CA 90071

Attention: Dennis Blank

Telecopier No: (213) 236-4096

Third Amended and Restated Credit Agreement

83

 

	 	 	CREDIT SUISSE

    as Lender
	

 	
 	

By:	

/s/  BRIAN CALDWELL      
	 	 	 	
 Name: Brian Caldwell

Title:    Director
	

 	
 	

By:	

/s/  NUPUR KUMAR      
	 	 	 	
 Name: Nupur Kumar

Title:    Associate
	

 	
 	

Address for Notices:
	

 	
 	

Credit Suisse

11 Madison Avenue

New York, NY 10010

Attention: Brian Caldwell

Telecopier No: (212) 743-2042

Third Amended and Restated Credit Agreement

84

 

	 	 	DEUTSCHE BANK TRUST COMPANY AMERICAS,

    as Lender
	

 	
 	

By:	

/s/  MARCUS M. TARKINGTON      
	 	 	 	
 Name: Marcus M. Tarkington

Title:    Director
	

 	
 	

By:	

/s/  PAUL O'LEARY      
	 	 	 	
 Name: Paul O'Leary

Title:    Vice President
	

 	
 	

Address for Notices:
	

 	
 	

Deutsche Bank Trust Company Americas

60 Wall Street

New York, NY 10005

Attention: Marcus Tarkington

Telecopier No: (212) 797-0070

Third Amended and Restated Credit Agreement

85

 

	 	 	GOLDMAN SACHS CREDIT PARTNERS L.P.,

    as Lender
	

 	
 	

By:	

/s/  MARK WALTON      
	 	 	 	
 Name: Mark Walton

Title:    Authorized Signatory
	

 	
 	

Address for Notices:
	

 	
 	

Goldman Sachs Credit Partners L.P.

30 Hudson Street

17th Floor

Jersey City, NJ 07302

Attention: Philip Green

Telecopier No: (212) 357-4597

Third Amended and Restated Credit Agreement

86

 

	 	 	LEHMAN BROTHERS COMMERCIAL BANK,

    as Lender
	

 	
 	

By:	

/s/  BRIAN MCNANY      
	 	 	 	
 Name: Brian McNany

Title:    Authorized Signatory
	

 	
 	

Address for Notices:
	

 	
 	

Lehman Brothers Commercial Bank

c/o Lehman Brothers

745 7th Avenue

5th Floor

New York, NY 10019

Attention: Janine Shugan

Telecopier No: (917) 522 0139

Third Amended and Restated Credit Agreement

87

 

	 	 	MERRILL LYNCH CAPITAL CORPORATION,

    as Lender
	

 	
 	

By:	

/s/  CAROL FEELEY      
	 	 	 	
 Name: Carol Feeley

Title:    Vice President
	

 	
 	

Address for Notices:
	

 	
 	

Merrill Lynch Capital Corporation

4 World Financial Center

22nd Floor

New York, NY 10080

Attention: Carol Feeley

Telecopier No: (212) 738-1186

Third Amended and Restated Credit Agreement

88

 

	 	 	THE ROYAL BANK OF SCOTLAND PLC,

    as Lender
	

 	
 	

By:	

/s/  MICHAEL CANAVAN      
	 	 	 	
 Name: Michael Canavan

Title:    Senior Vice President
	

 	
 	

Address for Notices:
	

 	
 	

The Royal Bank of Scotland plc

101 Park Avenue

New York, NY 10178

Attention: Michael Canavan

Telecopier No: (212) 401-3419

Third Amended and Restated Credit Agreement

89

 

	 	 	UBS LOAN FINANCE LLC,

    as Lender
	

 	
 	

By:	

/s/  IRJA R. OTSA      
	 	 	 	
 Name: Irja R. Otsa

Title:    Associate Director
	

 	
 	

By:	

/s/  RICHARD L. TAVROW      
	 	 	 	
 Name: Richard L. Tavrow

Title:    Director
	

 	
 	

Address for Notices:
	

 	
 	

UBS Loan Finance LLC

677 Washington Blvd.

6th Floor South

Stamford, CT 06901

Attention: Richard Tavrow

Telecopier No: (203) 719-3888

Third Amended and Restated Credit Agreement

90

 

	 	 	BAYERISCHE LANDESBANK,

    as Lender
	

 	
 	

By:	

/s/  JAMES KING      
	 	 	 	
 Name: James King

Title:    First Vice President
	

 	
 	

By:	

/s/  ANNETTE SCHMIDT      
	 	 	 	
 Name: Annette Schmidt

Title:    First Vice President
	

 	
 	

Address for Notices:
	

 	
 	

Bayerische Landesbank

560 Lexington Avenue

New York, NY 10022

Attention: Stephen Spencer

Telecopier No: (212) 230 9117

Third Amended and Restated Credit Agreement

91

 

	 	 	BNP PARIBAS,

    as Lender
	

 	
 	

By:	

/s/  FRANCIS J. DELANEY      
	 	 	 	
 Name: Francis J. Delaney

Title:    Managing Director
	

 	
 	

By:	

/s/  LEONARDO OSORIO      
	 	 	 	
 Name: Leonardo Osorio

Title:    Director
	

 	
 	

Address for Notices:
	

 	
 	

BNP Paribas

787 Seventh Avenue

New York, NY 10019

Attention: Francis DeLaney

Telecopier No: (212) 841-2555

Third Amended and Restated Credit Agreement

92

 

	 	 	THE BANK OF NOVA SCOTIA,

    as Lender
	

 	
 	

By:	

/s/  THANE RATTEW      
	 	 	 	
 Name: Thane Rattew

Title:    Managing Director
	

 	
 	

Address for Notices:
	

 	
 	

The Bank of Nova Scotia

1 Liberty Plaza

Floors 22-26

Attention: Isabel Abella

Telecopier No: (212) 225-5172

Third Amended and Restated Credit Agreement

93

 

	 	 	SOCIÉTÉ GÉNÉRALE,

    as Lender
	

 	
 	

By:	

/s/  EFFIE HAN      
	 	 	 	
 Name: Effie Han

Title:    Vice President
	

 	
 	

Address for Notices:
	

 	
 	

Société Générale

1221 Avenue of the Americas

New York, NY 10020

Attention: Ambrish Thanawala

Telecopier No: (212) 278-7862

Third Amended and Restated Credit Agreement

94

 

	 	 	JPMORGAN CHASE BANK, N.A.,

    as Lender
	

 	
 	

By:	

/s/  THOMAS CASEY      
	 	 	 	
 Name: Thomas Casey

Title:    Vice President
	

 	
 	

Address for Notices:
	

 	
 	

JPMorgan Chase Bank, N.A.

270 Park Avenue

4th Floor

New York, NY 10017-2014

Attention: Thomas L. Casey

Telecopier No.: (212)-270-3089

Third Amended and Restated Credit Agreement

95

 

	 	 	CITICORP NORTH AMERICA, INC.,

    as Lender
	

 	
 	

By:	

/s/  NIETZSCHE RODRICKS      
	 	 	 	
 Name: Nietzsche Rodricks

Title:    Vice President
	

 	
 	

Address for Notices:
	

 	
 	

Citicorp North America, Inc.

2 Penns Way

Suite 110

New Castle, DE 19720

Attention: Diane Stewart

Telecopier No.: (212) 994-0847

Third Amended and Restated Credit Agreement

96

Schedule 3.2.1

to Credit Agreement 

Midwest Generation, LLC

Pricing Grid  

	

	BASIS FOR PRICING(2)	 	LEVEL 1	 	LEVEL 2	 	LEVEL 3	 	LEVEL 4
	

 	
 	

BBB By S&P

Baa2 By Moody's

BBB By Fitch	
 	

BBB- By S&P

Baa3 By Moody's

BBB- By Fitch	
 	

BB+ By S&P

Ba1 By Moody's

BB+ By Fitch	
 	

Debt Rating Less

Than Level 3
	

	Commitment Fee(1)	 	10 bps	 	12.5 bps	 	17.5 bps	 	20 bps
	

	Applicable Margin for Base Rate Loans	 	0 bps	 	0 bps	 	0 bps	 	0.15 bps
	

	Applicable Margin for LIBO Rate Loans	 	45 bps	 	55 bps	 	87.5 bps	 	115 bps
	

	Participation Fee	 	45 bps	 	55 bps	 	87.5 bps	 	115 bps
	

	Additional Margin(3)	 	10 bps	 	10 bps	 	12.5 bps	 	12.5 bps
	

bps = basis points per annum 

	(1)
	Paid
quarterly in arrears on each bank's unused commitment.

	(2)
	The
Borrower's Debt Rating shall be the rating by each of S&P, Moody's and Fitch. If each of the three Debt Ratings are at different levels, the lower of the two highest Debt Ratings
shall determine placement in the Pricing Grid.

	(3)
	Additional
margin is applicable for any Interest Period in which average utilized Commitments are greater than 50% of all Commitments.

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00127-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00127-of-00352.parquet"}]]