Document:

China Education Cloud Platform (Xuezhi)
Development Contract

 

Party A: Harbin Zhong He Li Da Education
Technology, Inc. (hereinafter referred to as Party A)

 

Party B: Beijing Jinkeruida Technology
Co., Ltd. (hereinafter referred to as Party B)

 

WHEREAS, Party A intends to entrust Party
B to develop the website “Xuezhi” of “China Education Cloud Platform,” for profits of Party A;

 

NOW THEREFORE, pursuant to the Contract
Law of the People's Republic of China and the relevant laws and regulations and in accordance with the principles of equality and
mutual benefits, both parties hereby agree as follows:

 

		I.	Definition:

 

The following terms
in this agreement shall have the following meanings:

 

		i.	Unless otherwise specified, “software” includes “software system”, which
means the current and future versions of the software that are developed and provided in the performance period of the agreement
as described in Annex I, including the software and related documents developed by Party B in the period of the contract.

 

		ii.	“Deliverables” refers to software delivered by Party B, including source code, installation
disk, technical documentation, user guide, operation manual, installation guide and test reports.

 

		iii.	“Delivery” refers to the behavior of Party B to hand in developed software within the
date specified by both sides. The completion of delivery by Party B does not mean that Party B has fulfilled all of its obligations
under this agreement.

 

		iv.	“Specifications” means the standards and norms of technology or other development tasks.

 

		v.	“Milestone” refers to certain the software or module that Party B completed in the
software development process which has the relative independence.

 

		vi.	“Source code” refers to the source code for the software. It must be used or understood
by skilled programmers, and can be printed as well as machine-readable or in other reasonable and necessary form, including the
assessment of the software, testing or other technical documents.

 

		vii.	“Trade secrets” refer to management information, methods, customer lists, business
data, product information, sales channels, technical know-how, source code, computer documentation owned by each party and not
known to the public, or any information explicitly defined as commercial secret and recognized by the law in the performance of
this agreement.

 

		viii.	“Business Day” means all working days except holidays, days unspecified refer to calendar
days.

 

    	 

    	 

    

 

		II.	The description of developed software:

 

		1.	This software is developed by Party A for “China Education Alliance Cloud Platform”.
The software's main function and objective is to build network video courses long distance
teaching system, online community services system serving students, parents and teachers, network Academic Management Services
system (including online preparation, online lesson plans, online jobs, Intelligent Questions)

 

		2.	Software system

 

The software system developed
by Party B is Xuezhi Website.

 

		3.	Software development target

 

The overall function of the software
shall conform to the functional requirements as described by Party A and meet the technology standards (accurate, efficient, safe,
reliable, open and practical) set by Party A.

 

		4.	Delivery schedules of the software

 

		1.	Delivery time is December 10, 2012;

 

		2.	Software development is divided into eight milestone phases. After the completion of each milestone
phases, the software shall be tested and delivered based on mutually recognized testing standards. The software development standard
used by Party B or testing standing applied by Party B shall not be lower than the industry standard.

 

		III.	The Software Development

 

		1.	Development

 

Upon signing of the agreement,
Party B shall make every effort to fulfill its obligations under the development plan, and shall complete and deliver each of the
milestones on time, and the quality standards shall be accepted by both parties.

 

		2.	Subcontract

 

Projects under this contract shall
not be subcontracted. Party B shall be liable for his breach in accordance with the relevant provisions of this agreement in the
event of breach of this provision.

 

		3.	Information and Data

 

Party A and B shall co-coordinate,
and have effective communication. In accordance with the provisions of the agreement and the needs of the project, Party B shall
understand the situation, gather relevant materials, survey the relevant functional personnel and understand existing data and
information of Party A, in order to conduct a comprehensive research and design of the software. Party A shall actively cooperate,
provide the relevant information and data, particularly the information and data related to the functions and objectives of the
software. If Party A does not provide all of the information and data that Party B needs to complete the agreement, Party A shall
be responsible for the damages resulting from its failure to provide.

 

    	 

    	 

    

 

		4.	Demand and Demand Analysis

 

		1.	Party A and Party B shall conduct the demands analysis together according to the description of
the software and its functions as prescribed in Article II and information and data provided by Party A. When Party A submits demand
specification, data and information, Party A may ask for advice or comments from Party B concerning software functions, goals,
the composition of demand involved and related technical issues, and Party B shall explain and respond in time.

 

		2.	After Party B obtaining the demand information and data, Party B shall timely complete the written
demand analysis. The demand analysis shall be approved by the Party A.

 

		5.	Demand Requirements specification, outline design specification and detailed design specification

 

		1.	After Party B obtaining the necessary information and data provided by Party A, Party B shall complete
demand specification before March 30, 2012, and complete outline design specification before April 15, 2012 and complete detailed
design specification before April 30, 2012. Upon completion, the three items shall be submitted to Party A for review and verification.
Party A shall review and verify the applicability, need and application of the software described therein. Party A shall complete
the review of demand specification before May 10, 2012, and complete outline design specification review before May 20, 2012, and
complete the review of detailed design specification before May 30, 2012. If Party A approves the above-mentioned documents, Party
A shall sign the above-mentioned documents. In the event of disagreement, Party A shall submit a written explanation to Party B
for review. If Party B does not consider it is not a problem, Party B shall explain to Party A. If the problems indeed exist, Party
B shall promptly revise and re-submit to the Party A for review and verification. Both parties shall repeat this procedure until
the two parties unanimously approve and sign.

 

		2.	The signoff of Party A on the above specifications shall only represent its approval of the applicability
need and application of the software. Party A shall not review the technical issues in the manual. If there is any technical problem
or technical adjustment related to Party B’s design in the manual, Party B shall be responsible.

 

    	 

    	 

    

 

		3.	If Party A does not complete its obligations under the agreement within the agreed timeframe, Party
B may accordingly extend its delivery time. If the delay causes the loss of Party B, Party A shall compensate the loss of Party
B.

 

		6.	Progress report

 

A the end of each month, Party
B shall submit a written progress report containing the project progress or implementation of milestone plan, completed software
development projects, any difficulties and obstacles, the expected results of the project, allocation of staff, any project changes
or anything associated with this project which shall be conveyed to Party A or requested by Party A. If any major problems or important
change occurs, Party B shall make a written report to Party A within 7 working days from the date of the occurrence of the event.
Party B shall reply with the project-related inquiries within 7 working days to Party A in other time. If Party B violates this
provision, Party B shall be responsible for the project delay or Party A’s inability to pay timely or cooperate. Party A
shall also reply to Party B within 7 working days after receipt of the written report from Party B.

 

		7.	Third-party supervision

 

Party A shall have the right to
retain a third party as a supervising officer of the software development. If Party A designates a third party as its supervising
officer, based on Party A’s authorization, the supervising officer shall have the same rights as Party A as stipulated in
the agreement to supervise this project. Supervisor shall have appropriate qualifications and exercise its supervision duties in
accordance with the law, or Party B shall have the right to refuse to accept supervision.

 

		IV.	The project changes

 

In order to maintain and take
into account the interests of all parties, and to ensure the quality of the developed software, after the execution of this contract,
Party A and Party B shall have the right to reasonably request changes, extension, replacement or modification of certain parts
of the project, including the increase or decrease of capacity of software / improve or enhance the technical parameters / change
the delivery or installation time and place. The parties hereby agree:

 

		1.	If Party A proposes changes in some parts of the project, Party A shall submit the request in writing
to Party B. Party B shall respond in writing within five working days, including the impact of the change on contract
price, project delivery date, system performance of the software, project technical parameters and the terms of the agreement,
etc.;

 

    	 

    	 

    

 

		2.	Upon receipt of the aforementioned response from Party B, Party A shall notify Party B in writing
if it accepts the aforementioned response. If Party A accepts the above response, the parties shall confirm the changes in writing
and perform the agreement according to the amendment.

 

		3.	If the Party A does not agree with Party B’s response on the change on the contract price
and project delivery date, but if these changes are not implemented, it will affect the normal use and main function of the software,
Party B shall implement the change requests. At the same time, the parties shall have the right to resolve the dispute in accordance
with the provisions of Article 13. Pending resolution of the dispute, Party A shall execute the change on price and project delivery
date as requested by Party B in its response.

 

		4.	As the total contract price relates to the total amount of the target of the agreement, the parties
hereby agree that if the changes proposed by Party A leads to the decrease in the total contract price, then Party A shall subsidize
Party B in the amount equivalent to 3% of the total contract price for every 10% decrease in the total contract price.

 

		5.	If Party B proposes project changes, Party B shall elaborate on the effect of the changes on contract
price, project delivery date, software performance and technical parameters, as well as the terms of the agreement.

 

		6.	After Party A receives notice of the above changes, Party A shall notify Party B in writing within
five working days whether Party B agree with and accept the changes or not. If Party A accepts the above reply of Party B, the
parties shall confirm this change in writing, and parties shall execute the agreement pursuant to the amendment. If the Party A
does not agree with the above recommendations of Party B, the parties shall execute the original agreement.

 

		V.	Delivery, receipt and acceptance

 

		1.	Delivery

 

		1.	Party B shall give a written notice to Party A five working days prior to the delivery. Party A
shall arrange to receive the delivery within five working days after receiving the notice. Party B shall test the deliverable pursuant
to mutually recognized testing standards to verify compliance with the provisions of this agreement prior to delivery.

 

		2.	If the delivery cannot be made in accordance with the timeline in the agreement due to Party A,
Party B shall postpone the delivery time accordingly. If Party B suffers loss as a result of the delay in delivery, Party A shall
indemnify Party B for the actual losses. If Party A can accept but refuse to accept the delivery, this shall be regarded completion
of delivery by Party B, and the Party A shall make payment in accordance with the agreement, unless otherwise agreed by the parties.

 

    	 

    	 

    

 

		2.	Content of delivery

 

		1.	Party B shall deliver in accordance with the terms of the agreement. The documents and files to
be delivered shall be in electronic formats and readable.

 

		2.	If Party A’s improper operation, inspection or other reasons causes problems in the project
delivered, Party B shall assist to solve the problem within 5 working days, upon request of Party A. Party A shall be responsible
for any cost incurred.

 

		3.	Acceptance

 

After Party A receives these deliverables,
Party A shall immediately test and evaluate the deliverables to confirm its compliance with the features and specifications of
the developed software. Party A shall submit to Party B a written explanation accept the deliverables within five working days.
If any defect occurs, Party A shall submit a description of the defect, and shall specify the part to be improved and Party B shall
immediately rectify the defects, and conduct testing and evaluation again. Party A shall again examine the system, issue written
acceptance or submit a defect report within five working days. Party A and Party B shall repeat this process until Party A accepts,
or the agreement is terminated by Party A pursuant to the laws or this agreement

 

		4.	Software systems trial operation

 

		1.	Since the delivery is accepted, Party A shall have a 30-day trial operation.

 

		2.	If Party B causes software problems during the trial operation, Party B shall promptly solve the
problems, and related costs shall be borne by Party B.

 

		3.	Party B shall cure the defects or solve problems within a reasonable period of time. If the above
defects or problem affects the realization of the basic functions and goals of the software, and the time spent on solving the
problems is more than five working days, then Party B shall be deemed in breach of delivery obligation, unless such problem is
caused by Party A.

 

		5.	System acceptance

 

		1.	After software trial operation is completed, Party A shall promptly test and accept the system
in accordance with the agreement. Party B shall notify Party A in writing of the acceptance, and Party A shall arrange the date
to complete software system acceptance in accordance with the provisions of the agreement within five working days upon receipt
of the acceptance notice.

 

    	 

    	 

    

 

		2.	If the software fails to pass the system acceptance as a result of Party B, Party B shall solve
the problem and bear the associated costs, and at the same time extend the trial operation period of 15 working days until the
software system is in full compliance with the acceptance criteria.

 

		3.	If the software fails to pass the system acceptance due to Party A, if this is caused by Party
A's computer system failure, Party A shall solve the problem within a reasonable period and accept again. If it is caused by reasons
other than the failure above, except for force majeure prescribed under the provisions of the agreement, if Party A fails to complete
acceptance within the stipulated time, Party B shall have the right to unilaterally complete the acceptance in a reasonable way
in its discretion and shall submit the acceptance report to Party A. This shall be considered completion of system acceptance.
During the unilateral acceptance by Party B, Party A shall provide the acceptance convenience. If Party A does not provide the
acceptance convenience within 5 working days after Party B proposes the unilateral acceptance, and the system shall be considered
passed the acceptance.

 

		VI.	Intellectual property and use right

 

		1.	Intellectual Property

 

Party A shall have the intellectual
property rights of the developed software. Party B shall not, in any way, disclose to, transfer, or permit any third parties any
related technology achievements, computer software, technology knowhow, secret information, technology files and documents without
the written permission of Party A. Unless otherwise for the needs of this project, Party B shall not in any way use the above information
and technology for profits. If Party B violates the provisions of this article, in addition to the immediate cessation of the breach,
Party B shall pay liquidated damages and compensation for loss of Party A.

 

		2.	Use rights

 

Party A shall have the right to
use the software.

 

		3.	The rights and obligations of the parties under the agreement shall not change in the event of
acquisition, merger, reorganization and spinoff. If any of the above ocurrs, the rights and obligations under this agreement shall
be transferred to the successor entity in the acquisition, merger, reorganization or spinoff. If the rights and obligations of
Party A and Party B under this agreement are transferred to their successor entity, then Party A, Party B and their respective
successor entity shall have the rights and obligations under the agreement, respectively.

 

    	 

    	 

    

 

		4.	Party B shall strictly abide by the related intellectual property rights and software copyright
protection laws and regulations, and test the software within the limits prescribed in the agreement. If Party B’s unauthorized
commercial duplication constitutes breach of the agreement or the breach causes loss of Party A, Party B shall be responsible for
any liability.

 

		VII.	Maintenance and training

 

		1.	Software maintenance and support

 

Party B agrees to provide software
maintenance and support services within the period stipulated in the agreement. Unless the Parties otherwise agree in writing,
if Party A use the software for commercial sale in accordance with the law or the agreement, Party B shall provide end users with
maintenance and support services. Upon expiration of the maintenance and support service, if Party A continues to engage Party
B to provide the above services, the parties shall enter into maintenance and support agreements separately.

 

		2.	Project training

 

Party B shall promptly provide
personnel training to the relative officer of Party A, and training objectives is to independently and skillfully complete the
operation to achieve the objectives and functions of the software set forth in the agreement.

 

		VIII.	Price and payment method

 

		1.	Price

 

The total price for the development
of software is RMB7, 800, 000.

 

		2.	Change in pricing

 

In the process of the project,
if Party A and Party B make any changes or modify any function or increase or decrease software modules by mutual consent, one
party or both parties shall negotiate a specific price after the modification based on the price set forth above.

 

		3.	Payment: Payments shall be made in installments on mutually agreed milestones.

 

		IX.	Warranties and Disclaimer

 

		1.	Party B warrants

 

		i.	conflicts of interest

 

Party B’s signing and execution
of the agreement or the files associated with the agreement will not:

 

		1)	conflict with the articles of association of Party B or laws, regulations or judgment that are
applicable to Party B;

 

		2)	conflict with the provisions of any legal documents with third parties, such as the guarantee agreement,
promise, contracts or lead to any breach, or cause the constraint of Party B’s rights.

 

    	 

    	 

    

 

		ii.	Party B warrants:

 

The fulfillment of Party B’s
obligations under the agreement and the delivery of the software are not subject to restrictions or limitations of any third party,
nor accept any constraints or restrictive obligations.

 

		iii.	infringement and being sued

 

Party B warrants that the development
of the software will not infringe the intellectual property rights or other rights of any third party, that there is no other pending
litigation against the rights to the software, or that the exercise of rights of the software by Party A will not infringe on the
legal rights of any third party.

 

		iv.	legitimate software

 

The software must be developed
in accordance with provisions of the software products and software standards prescribed by the national government.

 

		v.	The software system delivered by Party B does not include any software that can automatically terminate
or hinder the operation of the system.

 

		vi.	If the software delivered by Party B needs to be registered with the relevant government authorities;
Party B shall ensure that the software has completed the above procedures.

 

		2.	Infringement damages

 

		i.	Party B agrees that if any third-party alleges the use of the software by Party A or its authorized
customer infringed on a third party's intellectual property rights or other property rights, Party B shall defend any action or
legal requests arising thereof. Party B agrees to pay the amount of compensation determined by the judgment or settlement. Party
A agrees that in event of such litigation, Party A shall promptly notify Party B and provide reasonable assistance to Party B to
deal with the litigation or requests. Party A shall deal with the related answer, defense or settlement with consent of Party B.
Party A shall, at its own expenses, to participate in the defense or settlement of the claim. If Party B fails to respond or settle
the claim due to economic or other reasons, Party A shall have the right to respond or settle, the costs of which shall be borne
by Party B.

 

		ii.	If the software or any part thereof was considered violations of the legitimate rights of the third
person in accordance with the law, or any agreed use or distribution of the software, exercise of any right granted by Party B
is considered to be infringement, Party B shall try to replace the software with a non-infringing software with the equal functions
or obtain the relevant authorization, so that Party A may continue to enjoy the rights under this agreement.

 

    	 

    	 

    

 

		iii.	If Party B, using its reasonable judgment with factual basis, determines that the software or any
part thereof may be identified by law as infringement of the legitimate rights of the third person, or use or distribution of the
software or exercise of the rights granted by Party B may be identified as infringement, Party B shall replace the software with
a non-infringing software with the equal functions or obtain the relevant authorization, so that Party A may continue to enjoy
the rights under this agreement. Party B shall be response for any infringement caused by the use of illegal software system by
Party A, or use of software that is not provided by Party B in the software or the modification in the software that is not made
by Party B.

 

		3.	Party A Warranty

 

Conflicts of interest

 

Party A’s signing and execution
of the agreement or related files will not:

 

		1)	conflict with Party A’s constitution or other applicable laws, regulations or judgments;

 

		2)	conflict with the provisions of any legal documents with third parties, such as the guarantee agreement,
promise, contracts or lead to any breach, or cause the constraint of Party B’s rights.

 

		X.	Confidentiality

 

		1.	Transmission of information

 

During the performance of the
agreement, either party can get the other’s trade secrets related to the project, for which both parties shall be cautious
in disclosing and accepting.

 

		2.	Confidentiality

 

The party with access to the other’s
trade secret shall only use the trade secret for performance of obligations under this agreement and shall be used by relevant
engineering and technology staff. The party with access to the other’s trade secret shall take appropriate and effective
action to protect the trade secrets, shall not use, disseminate or disclose the trade secret without authorization. Unless with
written permission of the other party or the information is no longer considered trade secrets by the owner, or have been public,
the trade secret shall not be disclosed within 10 years.

 

		3.	Non-compete

 

Party A and B agree that, during
the performance of the agreement as well as [   ] years after the full performance of the agreement, the parties shall not use the
trade secret of each other obtained during the execution of the project, or engage in the competing business with each other, nor
employ in any manner each other’s technology or management personnel in the project.

 

    	 

    	 

    

 

		4.	Information Security

 

Party A and Party B agree to
take appropriate safety measures to comply with the aforementioned obligations. Upon reasonable request of one party, the other
party can check if the security measures taken the other party meet the above requirements. 

 

		XI.	Breach and liability

 

		1.	Delivery breach

 

Party B shall complete and deliver
the project within the time stipulated in the agreement. If the development gets delayed, Party A agrees to provide Party B with
a 30-day grace period, there shall be liability for Party B within the grace period. If Party B during the grace period fails to
complete or deliver the project in accordance with the provisions of the agreement, in addition to the damages, Party A shall the
right to request Party B to take remedial measures and continue to fulfill obligations under this agreement. The specific method
for determining the amount of the damages is as follows:

 

		1)	For every delay of 15 days, Party B shall pay liquidated damages of 5% of the total contract price,
but the total amount of liquidated damages shall not exceed 20% of the total contract price;

 

		2)	If the extension exceeds 120 days, in addition to the agreed liquidated damages, Party A shall
have the right to terminate the agreement and require Party B to pay 20% of the total contract price as compensation for Party
A. If Party A thus terminates this agreement, Party B shall return within two weeks payments made by Party A and destroy all the
basic files and raw data in accordance with the Party's instructions and compensate Party A for direct and indirect losses.

 

		2.	Payment default

 

		1)	If Party A fails to make payment within the time prescribed by the agreement, for each extension
of 15 days, Party A shall pay liquidated damages of 5% of the total contract price, but the total amount of liquidated damages
shall not exceed 20% of the total contract price;

 

		2)	If the extension exceeds 120 days, in addition to the agreed liquidated damages, Party B shall
have the right to terminate the agreement and require Party A to pay 20% of the total contract price as compensation for Party
B.

 

		3)	If the parties continue to execute the agreement, in addition to payment of the liquidated damages,
Party A shall pay in accordance with the provisions of the agreement and the dates for Party B’s performance shall be extended
accordingly;

 

    	 

    	 

    

 

		4)	If Party B chooses to terminate the agreement, Party A shall pay Party B for the delivered and
completed software. After payment of the Party A, Party B shall deliver the paid software.

 

		3.	The confidentiality breach

 

Any party in violation of the
confidentiality obligations under this agreement shall pay 20% of the total contract price as liquidated damages. If the actual
loss including the profits exceed 20% of the total contract price, then the party suffering the loss shall have the right to demand
the breaching party to pay the amount exceeding 20% of the total contract price.

 

		4.	Other default

 

Any party in violation of its
obligations under this agreement, except otherwise provided in the agreement, the breaching party shall pay 20% of the total contract
price as liquidated damages to the other party.

 

		5.	In the event of default, if the non-breaching party requests the breaching party to pay liquidated
damages, it shall send written request, including an event of default, liquidated damages, payment time and manner. After receipt
of such notification, the defaulting party shall reply within five days, and to pay liquidated damages. If the parties can not
reach a consensus on the terms and conditions in accordance with the provisions in the agreement, they shall follow the dispute
resolution provisions to solve their disputes. Neither party shall take illegal means or undermine the project to obtain liquidated
damages.

 

		XII.	General Terms and Conditions

 

		1.	If the attachments of this agreement or any document signed before the agreement t was signed conflict
or are inconsistent with the terms of this agreement, the agreement shall prevail.

 

		2.	Either party may disclose in accordance with its operational needs the existence or nature of this
agreement, but the specific terms of the agreement, without the other's consent, shall not be disclosed to third parties.

 

		3.	Force majeure

 

		1)	In the event of earthquakes, typhoons, floods, fires, wars, and other unforeseen and unpredicted
force majeure which can not be prevented, overcome or avoided and directly affect the performance of the agreement the party affected
by the force majeure party shall be exempted from related obligations under the agreement. The party affected by the force majeure
shall immediately notify the other party in writing, and provide details on the force majeure and reasons and valid proof for the
inability to perform the agreement or partially unable to perform the agreement or delayed performance within 15 days. The parties
shall discuss whether to terminate the agreement, or partially exempt the performance of the agreement, or postpone the performance
of the agreement based on the impact of the force majeure. If the force majeure occurs while one party is late in performing its
obligation under the agreement, the obligations for the late party shall not be exempted.

 

    	 

    	 

    

 

		2)	The party affected by the force majeure shall take appropriate measures to mitigate the impact
the force majeure on the performance of this agreement. If the loss is increased as a result of failure to take appropriate actions,
then the party that fails to take appropriate actions shall not claim for exemption or damages for the increased loss.

 

		XIII.	Dispute resolution

 

		1.	If any dispute arises during the performance of the agreement, the parties shall first resolve
the dispute through friendly negotiation. If the negotiation fails, the two parties agree solve the dispute in the following manner:

 

		1)	submit to the Beijing Association of Information and Law for mediation and solve the dispute in
accordance with its mediation rules;

 

		2)	Submit to Beijing Arbitration Commission for arbitration in accordance with its arbitration rules;

 

		2.	If any dispute has been submitted for arbitration or to the people's court for litigation, except
the disputed matter or related agreement terms in dispute, the parties shall continue to fulfill other obligations under this agreement.

 

		XIV.	Effectiveness, Amendment and Termination of the Agreement

 

		1.	The agreement shall become effective after being signed or stamped by the representative designated
by each of the parties.

 

		2.	If any of the following occurs, either party shall have the right to terminate the agreement, subject
to notice to the other party in writing:

 

		1)	one party is bankrupted, revoked, or has entered the stage of liquidation or dissolution, or has
been shut down in accordance with the law;

 

		2)	the financial situation of one party is seriously deteriorated, and the party is unable to pay
its debts as they become due;

 

		3)	Other reasons for termination prescribed by the agreement or pursuant to the law.

 

    	 

    	 

    

 

Except as otherwise provided
in this agreement and the laws and regulations, if any of the above happens to one party, this party shall be considered breaching
the agreement, the other party shall have the right to pursue the liability of breach from the breaching party in accordance with
the provisions of the agreement.

 

		3.	Once the agreement has been signed, no party shall amend the agreement freely without mutual consent.
If there is any change, supplement or amendment during the execution of the agreement, the parties shall enter into separate agreements
in writing.

 

		4.	The agreement shall have duplicate copies, with one copy for each party, and each copy shall have
the same legal effect.

 

Party A: Harbin Zhonghelida Education
Technology, Inc. 

                

Signature Date: 3/01/ 2012

 

Party B:       Beijing Jinkeruida Technology
Co., Ltd.                  

 

Signature Date: 3/01/ 2012Exhibit 4.26

 

PROMISSORY NOTE COMBINATION #7 AGREEMENT

 

This Promissory Note
Combination #7 Agreement, hereinafter referred to as “Note Combination #7”, entered into effective the 16th day of
November, 2012 hereinafter referred to as the “Effective Date”, by and among Intellinetics, Inc, hereinafter called
“Maker” and Alpharion Capital Partners, hereinafter called “Lender”.

 

Alpharion Note #6:

WHEREAS, Maker and
Lender have entered into a Promissory Note and Subscription Agreement dated December 1, 2011 “December 1, 2011 Issuance Date”
for the amount of SEVEN THOUSAND FIVE HUNDRED AND NO/100 DOLLARS ($7,500), hereinafter referred to as “Alpharion Note #6”.
Said Alpharion Note #6 was originally due one hundred eighty days from its December 1, 2011 issuance date.

 

WHEREAS, Maker and
Lender have entered into a Promissory Note Extension Agreement dated May 29, 2012 extending the Alpharion Note #6 to a due date
that is two-hundred seventy days from the December 1, 2011 Issuance Date.

 

WHEREAS, Maker and
Lender have entered into a Promissory Note Second Extension Agreement dated August 27, 2012 extending the Alpharion Note #6 to
a to a due date of November 16, 2012. All other provisions of Alpharion Note #6 were unchanged.

 

Alpharion Note #24:

WHEREAS, Maker and
Lender have entered into a Promissory Note and Subscription Agreement dated May 21, 2012 “May 21, 2012 Issuance Date”
for the amount of FIFTY THOUSAND AND 00/100 DOLLARS ($50,000), hereinafter referred to as “Alpharion Note #24”. Said
Alpharion Note #24 was originally due one hundred and eighty days from the May 21, 2012 Issuance Date.

 

Alpharion Note #27:

WHEREAS, Maker and
Lender have entered into a Promissory Note and Subscription Agreement dated September 18, 2012 “September 18, 2012 Issuance
Date” for the amount of SEVENTY FOUR THOUSAND AND NO/100 DOLLARS ($74,000), hereinafter referred to as “Alpharion Note
#27”. Said Alpharion Note #27 was originally due one sixty days from the September 18, 2012 Issuance Date. All other provisions
of Alpharion Note #27 were unchanged.

 

Alpharion Note Combination #7:

WHEREAS, Maker and
Lender desire to enter into this Note Combination #7 in order to combine Alpharion Note #6, Alpharion Note #24 and Alpharion Note
#27 for a total of $131,500 and extend the due date for an additional thirty days to December 16, 2012.

 

    	1

    	 

    

 

NOW, THEREFORE, it
is duly agreed by both Maker and Lender to combine Alpharion Note #6, Alpharion Note #24 and Alpharion Note #27 for a total of
$131,500 (hereinafter collectively referred to as the “Alpharion $131,500 Note”), and extend the due date of such Alpharion
$131,500 Note to a due date until December 16, 2012.

 

All other provisions of Alpharion Note
#6, Alpharion Note #24 and Alpharion Note #27 (if applicable) shall prevail unless otherwise written.

 

IN WITNESS WHEREOF,
the undersigned Maker and Lender have duly executed this Note Combination #7 as of the Effective Date.

 

	 	INTELLINETICS, INC.
	 	 	 
	 	By:	/s/ William J. Santiago
	 	 
	 	ALPHARION CAPITAL PARTNERS, INC.
	 	 	 
	 	By:	/s/ Rick Hughes

 

    	2

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00215-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00215-of-00352.parquet"}]]