Document:

EXHIBIT 10.30

 

ASSET AND SHARE PURCHASE
AGREEMENT

 

This ASSET AND SHARE
PURCHASE AGREEMENT (this “Agreement”) is made and entered into as of September 30,
2008, by and among Methode Electronics, Inc., a Delaware corporation (“Methode”);
and Hetronic Holding LLC, an Oklahoma limited liability company (“Hetronic
Holding”), Hetronic International, Inc., an Oklahoma corporation (“Hetronic
International”), Hetronic USA Inc., an Oklahoma corporation (“Hetronic
USA”), Hetronic West, Inc., an Oklahoma corporation (“Hetronic West”),
Hetronic Europe GmbH, a German company with limited liability (“Hetronic
Europe”), Hetronic Malta Limited, a limited liability company incorporated
and registered in Malta with registration number C16025 (“Hetronic Malta”),
and Max Heckl (the “Shareholder”). 
Hetronic International, Hetronic USA, Hetronic West, Hetronic Europe and
Hetronic Malta are herein sometimes referred to individually as a “Seller”
and collectively, on a joint and several basis, as the “Sellers.” The
Sellers, Hetronic Holding and the Shareholder are herein sometimes referred to
individually as a “Selling Party” and collectively, on a joint and
several basis, as the “Selling Parties.” 
Capitalized terms used but not defined in this Agreement shall have the
respective meanings set forth in the Appendix of Definitions attached hereto
and made a part hereof.

 

RECITALS:

 

WHEREAS, the Shareholder is
the record and beneficial owner of ninety seven percent of the outstanding
membership interest of Hetronic Holding, which in turn directly or indirectly
holds all or a substantial majority of the stock or other equity interest in
each of the Sellers and Hetronic Asia Manufacturing & Trading Corp., a
corporation incorporated in the Republic of the Philippines (“Hetronic Asia,”
together with the Sellers, collectively the “Target Companies” and each,
individually, a “Target Company”);

 

WHEREAS, Hetronic Holding is
the record and beneficial owner of seventy nine thousand four hundred eighty
(79,480) shares, par value of One Hundred Philippine pesos per share, of the
issued and outstanding stock of Hetronic Asia (the “Purchased Shares”);

 

WHEREAS, the individuals
identified on Schedule 5.4.2 hereto (each an “Management
Shareholder” and collectively the “Management Shareholders”) are
collectively the record and beneficial owners of three thousand twenty (3,020)
shares, par value of One Hundred Philippine pesos per share, of the issued and
outstanding stock of Hetronic Asia (the “Management Shares” and,
together with the Purchased Shares, the “Hetronic Asia Shares”);

 

WHEREAS, the Management
Shareholders and Hetronic Holding (each a “Hetronic Asia Shareholder”
and collectively the “Hetronic Asia Shareholders”) are the beneficial
owners of all of the Hetronic Asia Shares;

 

WHEREAS, the Target
Companies are engaged in the business of developing, manufacturing, marketing
and selling radio remote control products for use in applications such 

 

1

 

as
tower cranes, overhead cranes, concrete pumps, work platforms, container
handling equipment and other specialty equipment;

 

WHEREAS, Methode has or will
form Subsidiaries in the various jurisdictions in which the Sellers have assets
or are engaged in business and will designate one or more such Subsidiaries (or
Methode itself) as the “Buyer” or “Buyers” pursuant to Section 8.3.3 below
(individually, each a “Buyer” and, collectively, the “Buyers”);

 

WHEREAS, Hetronic Holding
wishes to sell, transfer and assign to the Buyers, and the Buyers wish to
purchase from Hetronic Holding, all of the Purchased Shares in exchange for the
consideration set forth herein upon and subject to the terms and conditions
herein set forth;

 

WHEREAS, the Sellers wish to
sell, transfer and assign to the Buyers, and the Buyers wish to purchase from
the Sellers, substantially all of the Sellers’ assets and properties (other
than the Excluded Assets) and to assume certain specified liabilities of
Sellers in exchange for the consideration set forth herein upon and subject to
the terms and conditions herein set forth; and

 

WHEREAS, Hetronic Holding
owns all of the issued and outstanding capital stock of Hetronic Deutschland
GmbH, a German company with limited liability formerly known as Hetronic
Steuersysteme GmbH (“Hetronic Deutschland”), which the parties
acknowledge is not included among the Sellers and is not selling its assets or
properties;

 

NOW, THEREFORE, in
consideration of the mutual covenants and agreements herein contained and in
reliance upon the representations and warranties hereinafter set forth, the
parties agree as follows.

 

1.             PURCHASE AND SALE OF ASSETS
AND SHARES.

 

1.1.          Agreement to Purchase and
Sell Assets. Subject to the terms and conditions contained
herein, each of the Sellers agrees to sell, assign, transfer, convey and
deliver to the Buyers, and Methode agrees to cause a Buyer to acquire from each
of the Sellers, at the Closing, free and clear of all claims or Liens of any
nature whatsoever, (except as otherwise disclosed in and permitted by this
Agreement), all right, title and interest in and to all of their respective
assets and properties wherever situated, except for those assets and properties
specifically excluded by Section 1.3 hereof (the “Purchased Assets”).
The Purchased Assets shall include, but not be limited to, the following:

 

1.1.1.       Machinery and Equipment.  All machinery and equipment (including spare
parts), vehicles, fixtures, capital works in process, tools, dies, patterns,
molds, furniture, data processing hardware, computer and systems hardware and
telephone system equipment and office equipment and supplies and similar
tangible personal property (including any of the foregoing which have been
purchased subject to any conditional sales or title retention agreement in
favor of any other Person) employed or utilized by Sellers, as the same may exist at the Closing, and including the
property described in Schedule 1.1.1 hereto, and all rights to
computer software embedded in or installed upon the foregoing.

 

2

 

1.1.2.       Receivables.  The Receivables of the Sellers as the same
may exist at the Closing, including all Receivables payable by any Target
Company to any Seller, together with Hetronic Malta’s right to receive payment
under the note receivable payable by Hetronic Asia to Hetronic Malta under the
loan agreement dated August 5, 2004 between Hetronic Asia and Hetronic
Malta, as amended (the “Asia-Malta Receivable”).

 

1.1.3.       Inventories.  All Inventories of the Sellers as the same
may exist at the Closing, together with all rights against suppliers of such
Inventories and all bills of lading, warehouseman’s receipts and other
instruments or documents representing rights to any item of Inventory in the
possession of third parties.

 

1.1.4.       Contract and Other Rights.  All of the Seller’s rights and interests in,
to and under all Contracts between it or them and any other party or parties
and all Contracts which have been acquired by it or them by assignment or in
any other manner (whether or not disclosed or required to be disclosed in any
schedule hereto), including the Contracts described in Schedule 1.1.4
hereof, and all rights of any of the Sellers thereunder; all prepayments and
deposits thereunder, and all claims, rights and causes of action of Sellers arising
thereunder against the other party to each such Contract and all other claims,
rights and causes of action of the Sellers against third parties.

 

1.1.5.       Intellectual Property and
Proprietary Rights.  All
Intellectual Property owned by, licensed by or used by any Seller, including
all Intellectual Property incorporated into the radio remote control products
developed, manufactured, marketed or sold by the Sellers, the corporate and
trade name “Hetronic,” derivatives and all telephone numbers of the Sellers,
including those rights described in Schedule 5.19 hereto.

 

1.1.6.       Records.  All books, records (including records
relating to Inventories of the Target Companies, all maintenance reports and
repair logs relating to any other Acquired Assets), customer lists, personnel
files, laboratory notebooks, budgets, plans, projections, reports and
documentation (including call reports, customer and regulatory correspondence)
and other current or historical files of Sellers and all confidential or proprietary information embodied thereby or
relating thereto (collectively, the “Acquired Records”).

 

1.1.7.       Other Assets.  All other assets of the Sellers, whether
real, personal, or tangible, intangible or mixed and whether or not reflected
in the Financial Statements or on the books or records of the Sellers,
including all goodwill arising from or in connection with the business of the
Sellers, deposits under all leases and any prepaid expenses and other deposits
or rights of Sellers, permits and licenses (including rights to club
memberships, sky boxes arrangements and tickets) to the extent transferable
under law, and all of Sellers’ choses in action, causes of action and
judgments, express and implied warranties and existing and inchoate claims,
rights and remedies related to any of the foregoing.

 

1.2.          Agreement to Purchase and
Sell Shares. Subject to the terms and conditions contained
herein, Hetronic Holding agrees to sell, assign, transfer, convey and deliver
to the Buyer designated by Methode, and Methode agrees to cause a Buyer to
acquire from Hetronic Holding, at the Closing, free and clear of all claims or
Liens of any nature whatsoever, all right, title and interest in and to the
Purchased Shares.

 

3

 

1.3.          Excluded Assets.  Notwithstanding anything to the contrary
contained herein, the following assets shall not be sold to the Buyers pursuant
to Section 1.1 and all of such Excluded Assets shall be retained by the
Sellers (the “Excluded Assets”):

 

1.3.1.       Certain Cash, Cash
Equivalents and Investments.  All of the petty cash, cash on deposit in
banks or other financial institutions, prepaid accounts and security deposits
of Sellers and other cash equivalents of Sellers, and any prepayments for
Taxes; and all certificates of deposit, bonds, stock and other securities and
investments of Sellers (other than the Purchased Shares), including the stock
issued by any Seller held by the Shareholder or any other Seller (other than
the Purchased Shares).

 

1.3.2.       Excluded Contracts.  All of the Sellers’ rights, Liabilities and
interests in, to and under (a) the Contracts described on Schedule 1.3,
(b) Contracts between any of the Selling Parties and third parties with
whom any of the Selling Parties have discussed the potential sale of the
Purchased Assets (or any substantial portion thereof), or the securities of any
of the Selling Parties pursuant to which such third parties have agreed to
preserve the confidentiality of information relating to the business of the
Sellers disclosed in the course of such discussions (the “Existing NDAs”),
(c) letters of intent and similar Contracts between any of the Selling
Parties and third parties pursuant to which the Selling Parties have discussed
the potential sale of the Purchased Assets (or any substantial portion
thereof), or the securities of any of the Selling Parties, and (d) this
Agreement and any other additional Contracts executed and delivered in
connection with this Agreement.

 

1.3.3.       Corporate and Tax Documents.  All rights in and to each Seller’s corporate
seal and other corporate documents and records of the Sellers, including the
corporate minute books, books and records relating to the Taxes of the Sellers and all confidential or proprietary
information embodied thereby or relating thereto (collectively, the “Excluded
Records”).

 

1.3.4.       Employee Plans.  All rights in and to the Employee Plans
maintained by the Sellers and the underlying Contracts.

 

1.3.5.       Insurance Policies.  All of the Sellers’ rights in and to the
insurance policies maintained by the Sellers.

 

1.3.6.       Certain Affiliate
Obligations. Any debt, obligation, Indebtedness or other
Liability arising outside the Ordinary Course of Business and owed or otherwise
payable by any of the other Selling Parties to any Seller, including Hetronic
Malta’s right to receive payment under the note receivable payable by Hetronic
Deutschland to Hetronic Malta; provided that, notwithstanding the foregoing,
Hetronic Malta’s right to receive payment under the Asia-Malta Receivable is acknowledged
to be a Purchased Asset.

 

1.3.7.       Hummer. One Hummer
and one Ford Mustang.

 

1.3.8.       Other Excluded Assets.  All rights in the assets and properties
described on Schedule 1.3.

 

4

 

1.4.          Documentation.  In order to effectuate the sale, conveyance,
transfer and assignment contemplated by Sections 1.1 and 1.2 hereof, the
Selling Parties shall execute and deliver on the Closing Date (or, if requested
by Methode, after the Closing) all such warranty deeds, bills of sale and other
documents or instruments of conveyance, transfer or assignment as shall be
necessary or appropriate to vest or confirm in the Buyer(s) marketable
title to all right, title and interest of the Selling Parties in and to all of
the Purchased Assets and Purchased Shares, all of which documents shall be
prepared by counsel for Methode and the Buyers acting reasonably, which
documents may include (i) separate instruments of conveyance for each
Seller for each class of assets in each jurisdiction in which Purchased Assets
are located, (ii) certificates of title or similar instruments duly
endorsed by the applicable the Selling Party in favor of the Buyer designated
by Methode, and (iii) duly endorsed stock certificates and/or instruments
of assignment conveying to a Buyer designated by Methode (and/or one or more
individuals nominated by Methode) all right, title and interest in the
Purchased Shares.

 

2.             CONSIDERATION.

 

2.1.          Purchase Price.  Subject to the terms and conditions contained
herein, in consideration of the Sellers’ sale of the Purchased Assets and
Hetronic Holding’s sale of the Purchased Shares to the Buyers at the Closing,
the Buyers shall assume, pay, perform and discharge, when and as due, the
Assumed Liabilities and Methode shall pay on behalf of the Buyers, or cause the
Buyers to pay, to the Selling Parties the aggregate consideration (the “Purchase
Price”) of Fifty Three Million Six Hundred Thirty Eight Thousand Six
Hundred Seventy Three United States Dollars ($53,638,673), subject to
post-Closing adjustment as provided in Section 2.2.  The Purchase Price shall be payable as
provided in Section 4.3, subject to adjustment as provided in Section 2.3.

 

2.2.          Reconciliation
of Net Book Value.

 

2.2.1.       June 30 Statement.  Exhibit A sets forth the book
value of the Acquired Assets, as they existed on June 30, 2008, less the
book value of the Acquired Liabilities, as they existed on June 30, 2008
(the “June 30 Net Book Value”), calculated consistent with the
historical practice of the Selling Parties in preparing the Financial
Statements (the “Historic Accounting Principles and Procedures”).

 

2.2.2.       Closing Statement.  Promptly following the Closing Date, the
Shareholder shall direct HSPG & Associates, P.C. (the “Seller’s
Accountant”) to prepare and submit to Methode a statement (the “Closing
Statement”) setting forth the book value of the Acquired Assets, as they
exist at the Closing Date, less the book value of the Acquired Liabilities, as
they exist at the Closing Date (“Closing Net Book Value”).  In
each case, the book value of Acquired Assets and the Acquired Liabilities shall
be determined in accordance with the Historic Accounting Principles and
Procedures (except that an accrual shall be made for earned vacation). The
Closing Statement and the schedules thereto shall show in reasonable detail the
means by which Closing Net Book Value was calculated (including listings of
Acquired Assets and the Acquired Liabilities). 
The Shareholder shall direct Seller’s Accountant to submit the Closing
Statement as soon as reasonably practical after the Closing and in no event
later than ninety days following the Closing Date. Methode shall provide to
Seller’s Accountant all information 

 

5

 

reasonably requested by
Seller’s Accountant and take all other reasonable actions required for the
preparation of the Closing Statement, and Methode shall provide Seller’s
Accountant with access to all records of the business of the Target Companies
and to all former employees of the Target Companies in order to assist in the
preparation of the Closing Statement.

 

2.2.3.       Disputed Adjustments. Upon receipt
of the Closing Statement, Methode and its accountants and representatives shall
be permitted during the succeeding thirty (30) day period to examine the
accounting records and work papers prepared by Seller’s Accountant in
connection with the preparation of the Closing Statement.  If Methode agrees to the Closing Statement
delivered by Seller’s Accountant, it shall become the final Closing Statement
(the “Final Closing Statement”). 
If Methode does not agree that the Closing Statement accurately sets
forth the Closing Net Book Value determined in accordance with the Historic
Accounting Principles and Procedures (except that an accrual shall be made for
earned vacation), Methode shall within thirty (30) days after delivery of the
Closing Statement to Methode, prepare and deliver to the Shareholder a detailed
list of disputed adjustments, including the amount of each of the adjustment
claimed by Methode (the “Disputed Adjustments”) to the Closing
Statement.  If Methode fails to deliver a
list of Disputed Adjustments within thirty (30) days after the delivery of the
Closing Statement to Methode, Methode shall be deemed to have agreed to the
Closing Statement.  The Shareholder and
Methode shall use their best efforts to resolve any Disputed Adjustments.  If the Shareholder and Methode are able to reach
an agreement on the Disputed Adjustments, the Closing Statement shall be amended
to reflect such agreement and shall become the Final Closing Statement.  If the Shareholder and Methode are unable to
reach an agreement on the Disputed Adjustments within thirty (30) days after
receipt of all Disputed Adjustments, then the Shareholder and Methode shall
select an Independent Accounting Firm in accordance with Section 2.4 and
shall cause such Independent Accounting Firm to review the Disputed Adjustments
and determine the final value of each of the Disputed Adjustments in a prompt
manner (and in any event within sixty (60) days of receipt of the Disputed
Adjustments).  In making such
determination, the Independent Accounting Firm shall only apply the Historic
Accounting Principles and Procedures (except that an accrual shall be made for
earned vacation).  In making such
determination, the Independent Accounting Firm shall consider only the items or
amounts in dispute (and any other items or amounts relating thereto), and the
determination of each Disputed Adjustment’s value, as so computed, shall not,
in any event,  exceed the amount of
dollars claimed by Methode.  The Closing
Statement shall then be amended to reflect the determination of the final value
of each of the Disputed Adjustments and shall become the Final Closing
Statement.  The Final Closing Statement
shall be deemed to be and shall be conclusive and binding on the parties to
this Agreement for purposes of determining the Closing Net Book Value.

 

2.3.          Settlement.  In the event that the Closing Net Book Value
set forth on the Final Closing Statement is less than the June 30 Net Book
Value plus One Million Five Hundred Thousand United States Dollars
($1,500,000), the Purchase Price shall be reduced by an amount equal to such
shortfall (the “Adjustment Amount”); provided that the Adjustment Amount
shall not exceed the funds in the Net Book Value Escrow Account.  Within twenty (20) calendar days after the
Final Closing Statement is determined and becomes final, the parties shall
jointly instruct the Escrow Agent to (i) pay the Adjustment Amount (if
any) to Methode out of the funds in the Net Book Value Escrow Account by wire
transfer in accordance with the instructions provided by Methode, and then (ii) release
any remaining funds in the Net Book Value Escrow 

 

6

 

Account to the Selling
Parties by wire transfer in accordance with the instructions provided by the
Shareholder.  The parties acknowledge and
agree that the Selling Parties shall have no obligation to pay to Methode any
portion of the Adjustment Amount not covered by the Net Book Value Escrow
Account, that Methode shall look solely to the Net Book Value Escrow Account
for payment of the Adjustment Amount and that the Selling Parties shall be and
hereby are released from any portion of the Adjustment Amount that exceeds the
Net Book Value Escrow Account.

 

2.4.          Independent Accounting Firm.

 

2.4.1.       Selection. The “Independent
Accounting Firm” shall be the firm of certified public accountants of
national or regional standing mutually agreed by Methode and Shareholder.  In the event that the Shareholder and Methode
are unable to agree upon the selection of the Independent Accounting Firm,
either party may provide written notice to the other, in which case the
Shareholder shall select a firm of certified public accountants of national or
regional standing and Methode shall select a firm of certified public
accountants of national or regional standing, and the two firms so selected
shall select a third firm of certified public accountants of national or
regional standing which Methode shall retain to act as the Independent
Accounting Firm.  In the event that an
Independent Accounting Firm selected hereunder is or becomes unwilling to
perform the duties assigned to such Independent Accounting Firm hereunder or
the Shareholder and Methode agree that the Independent Accounting Firm should
be replaced, the parties shall select replacement Independent Accounting Firm
in the same manner as specified in this Section 2.4 for the original
Independent Accounting Firm.

 

2.4.2.       Independent Accounting Firm
Fees and Expenses. The fees, costs and expenses of the Seller’s
Accountant in preparing the Closing Statement shall be shared equally by
Methode and the Shareholder. The fees, costs and expenses of any Independent
Accounting Firm in assisting with the resolution or in resolving any Disputed
Adjustments shall be born by Methode if the Closing Net Book Value is unchanged
as a result of such resolution and by the Shareholder if the Closing Net Book
Value decreases as a result of such resolution.

 

2.5.          Allocation
of Purchase Price.  Attached as
Schedule 2.5 is the parties good faith determination of the
allocation of the Purchase Price among the Purchased Assets and Purchased
Shares, by jurisdiction and by asset category, in accordance with Code Section 1060
and the Treasury regulations thereunder (and any similar provision of state,
local or foreign law, as appropriate). 
Within thirty (30) calendar days after the Final Closing Statement is
determined and become final, Methode shall determine and deliver to the
Shareholder, Methode’s good faith determination of the allocation of the
Purchase Price (and all other capitalized costs) among the Purchased Assets and
Purchased Shares, by jurisdiction and by asset category, after adjustment to
reflect the final determination of the Closing Net Book Value in accordance
with Section 2.3, which adjusted allocation shall be made in accordance
with Code Section 1060 and the Treasury regulations thereunder (and any
similar provision of state, local or foreign law, as appropriate), and which
allocation shall be binding upon Methode and the Selling Parties.  Methode and the Selling Parties and their
Affiliates shall report, act and file Tax Returns (including Internal Revenue
Service Form 8594) in all respects and for all tax purposes consistent
with such allocation.  Neither Methode
nor the Selling Parties shall take any position (whether in tax 

 

7

 

audits, tax returns or otherwise)
that is inconsistent with such allocation unless required to do so by
applicable law.

 

3.             ASSUMED LIABILITIES AND
EXCLUDED LIABILITIES.

 

3.1.          Assumed Liabilities. On the terms
and subject to the conditions contained herein, at the Closing, the Buyers
shall assume and agree to perform and discharge when and as due the liabilities
and obligations set forth in Sections 3.1.1, 3.1.2 and 3.1.3 as the same may
exist at the Closing Date, and no others (the “Assumed Liabilities”):

 

3.1.1.       Accounts Payable and
Ordinary Course Liabilities.  The current liabilities consisting of
accounts payable and accrued expenses of the Sellers arising in the Ordinary
Course of Business (including accounts payable of the Sellers payable to other
Target Companies solely to the extent that such payables are included in the
Acquired Assets as Receivables of the applicable Target Company payee) as they
exist at the Closing Date, in each case to the extent reflected on the Final
Closing Statement.

 

3.1.2.       Executory Agreements.  Liabilities and obligations which exist at or
accrue following the Closing Date under the Contracts described in Section 1.1.4
hereof, but excluding (i) Contracts required to be disclosed in Schedule 5.11,
Schedule 5.12, Schedule 5.17 or Schedule 5.22
and not disclosed thereon, and (ii) Contracts described in Section 1.3
hereof.

 

3.1.3.       Warranty Claims.  The warranty obligations of the Sellers
pending as of or arising after the Closing Date under the Hetronic Warranties
identified on Schedule 5.24 for finished goods or components or
parts sold by the Sellers in the ordinary course on or prior to the Closing
Date or for Inventory acquired by Buyers from any Seller hereunder and
subsequently sold by Buyer (collectively, the “Assumed Warranty Claims”).

 

3.2.          Excluded Liabilities.  Except as specifically provided in Section 3.1
hereof, neither Methode nor any Buyer shall assume, or in any way become liable
for, any Liabilities of the Selling Parties of any kind or nature, whether
accrued, absolute, contingent or otherwise, or whether due or to become due, or
otherwise, whether known or unknown, arising out of events, transactions or
facts which shall have occurred, arisen or existed on or prior to the Closing
Date, which Liabilities, if ever in existence, shall continue to be Liabilities
of the Selling Parties (the “Excluded Liabilities”).

 

4.             CLOSING.

 

4.1.          Closing.  The consummation of the purchase and sale of
the Purchased Assets and Purchased Shares as contemplated by this Agreement
(the “Closing”) shall take place on September 30, 2008, subject to
the satisfaction or waiver of all of the conditions to the Selling Parties’ and
Methode’s obligations to close set forth in Section 8, or on such other
date as may be mutually agreed upon by Methode and the Shareholder (the “Closing
Date”).  The Parties anticipate the
Closing Date to occur on the date of execution and delivery of this Agreement.

 

8

 

4.2.          Closing Deliverables. At the
Closing, (i) the Selling Parties will deliver to Methode the various
agreements, certificates, opinions and documents referred to in Section 8.2,
(ii) Methode will deliver to the Selling Parties the various agreements,
certificates, opinions and documents referred to in Section 8.3, (iii) the
Sellers will transfer, assign, convey and deliver to Methode instruments of
assignment conveying all right, title and interest in the Purchased Assets,
free and clear of all Liens, (iii) the Selling Parties will transfer,
assign, convey and deliver to Methode instruments of assignment conveying all
right, title and interest in the Purchased Shares, free and clear of all Liens,
and (v) Methode will pay the Closing Payment as provided in Section 4.3.

 

4.3.          Closing Payment. At the
Closing, Methode shall deliver, or cause the Buyers to deliver, the sum of
Fifty Three Million Six Hundred Thirty Eight Thousand Six Hundred Seventy Three
United States Dollars ($53,638,673) (the “Closing Payment”) as follows:

 

(a)           Methode shall deliver, or
cause the Buyers to deliver, the sum of Five Million Dollars ($5,000,000) to
JPMorgan Chase Bank, National Association (the “Escrow Agent”) to be
held in the account designated as the “Indemnity Escrow Account” under the
Escrow Agreement (the “Indemnity Escrow Account”).

 

(b)           Methode shall deliver, or
cause the Buyers to deliver, the sum of One Million Five Hundred Thousand
Dollars ($1,500,000) to the Escrow Agent to be held in the account designated
as the “Net Book Value Escrow Account” under the Escrow Agreement (the “Net
Book Value Escrow Account”).

 

(c)           after payment of the
foregoing amount, Methode shall pay, or cause the Buyers to pay, any amounts
identified in the Payoff Letters delivered pursuant to Section 8.2.5 (if
any) as required to discharge all Liabilities owed to the Persons issuing such
Payoff Letters, such amounts to be paid in accordance with the instructions set
forth in such Payoff Letters;

 

(d)           after payment of the
foregoing amounts, Methode shall pay, or cause the Buyers to pay, to the
Selling Parties the remainder of the Closing Payment in cash, payable by wire
transfer in accordance with wire instructions provided by the Shareholder in
writing at least five business days prior to the Closing Date (which wire
instructions may designate a single account to which payment to all Selling
Parties is to be made on an aggregate basis).

 

4.4.          Location and Effective Time
of Closing.  The Closing
shall be held by exchange of documents by facsimile or by e-mail in portable
document format (or other mutually acceptable format), provided that if the
Parties elect for a physical Closing for all or a portion of the transaction,
it shall be held at the offices of Hetronic International, 3000 NW 149th
Street, Oklahoma City, Oklahoma 73134, USA, or such other location as may be
agreed by the parties. The Closing shall be held at 1:00 p.m. (Oklahoma
City time) on the Closing Date or such other time as may be agreed by the
parties. Title to the Purchased Assets and Purchased Shares shall be deemed to
have been transferred to the Buyers at 11:59 p.m. (Oklahoma City time) on
the Closing Date.

 

9

 

5.             REPRESENTATIONS AND
WARRANTIES OF SELLING PARTIES.

 

As an inducement for Methode
to enter into this Agreement, each of the Selling Parties, jointly and
severally, represents and warrants to Methode as follows:

 

5.1.          Organization and Good
Standing.  Each Target
Company is an organization of the nature identified in Schedule 5.1
and is duly organized, validly existing and in good standing under the laws of
the jurisdiction identified in Schedule 5.1, and has all requisite
power and authority to own or hold under lease its properties and assets and to
carry on its business as now conducted. 
Each Target Company is duly qualified to do business and is in good
standing as a foreign corporation in each jurisdiction in which the nature of
its activities or the ownership or leasing of property requires such
qualification, and such jurisdictions are listed on Schedule 5.1.

 

5.2.          Enforceability and
Authorization.  Each
Selling Party and Hetronic Asia has all necessary corporate power and authority
to execute and deliver all agreements and documents to be executed and
delivered by it pursuant to this Agreement, and to consummate the transactions
contemplated thereby.  The execution,
delivery and performance of the agreements and documents to be executed and
delivered pursuant to this Agreement, and the consummation of the transactions
contemplated thereby, have been duly approved and authorized by all necessary
corporate, company or similar actions on behalf of each Selling Party and
Hetronic Asia.  All agreements and
documents to be executed and delivered by each Selling Party and Hetronic Asia
pursuant to this Agreement will constitute, the valid and binding agreements of
such Selling Party and Hetronic Asia, as applicable, enforceable in accordance
with their respective terms, except that (i) such enforcement may be
subject to applicable bankruptcy, insolvency, reorganization, moratorium or
other similar Laws, now or hereafter in effect, affecting creditors’ rights
generally, and (ii) the remedy of specific performance and injunctive and
other forms of equitable relief may be subject to equitable defenses and to the
discretion of the court before which any proceeding therefor may be brought.

 

5.3.          No Conflict; Consents.  Except as set forth on Schedule 5.3
hereto, neither the execution and delivery of this Agreement, nor the
consummation of the transactions contemplated hereby, will constitute a
violation of, or be in conflict with, or result in a cancellation of or right
to cancel, or constitute a default under, or create (or cause the acceleration
of the maturity of) any debt, obligation or Liability affecting the Acquired
Assets, Purchased Shares or Hetronic Asia, or result in the creation or
imposition of any Lien upon the Acquired Assets or Purchased Shares under: (a) any
term or provision of the Organizational Documentation of any Selling Party or
Hetronic Asia; (b) any judgment, decree, order, regulation or rule of
any court or other Governmental Authority; (c) any Law; or (d) any
Contract to which any Selling Party or Hetronic Asia is a party or by which any
Selling Party, Hetronic Asia or the Acquired Assets are bound. Neither the
execution and delivery of this Agreement by the Selling Parties, nor of any
other agreement or document to be executed and delivered by them pursuant
hereto, nor the consummation by them of the transactions contemplated hereby or
thereby will cause any change in the rights or obligations of any party under
any Contract to which any Target Company is a party to or by which any Target
Company or the Acquired Assets or the Purchased Shares are bound that have a
material effect upon the Acquired Assets or the Purchased Shares.

 

10

 

Except as set forth on Schedule 5.3
hereto, no consent of, or notice to, any Governmental Authority or any other
Person is required to be obtained or given by any Selling Party or Hetronic
Asia in connection with the execution, delivery or performance of this
Agreement by any Selling Party or any other agreement or document to be
executed, delivered or performed hereunder by any Selling Party, or to enable
the Buyers and Hetronic Asia to continue to conduct the business of the Target
Companies after the Closing in the manner in which they are currently
conducted.

 

5.4.          Capitalization
and Ownership; Corporate Matters.

 

5.4.1.       Ownership of Sellers.  The Shareholder is the record and beneficial
owner of ninety seven percent (97%) of the outstanding membership interest of
Hetronic Holding and Monika Heckl Trust, Nichole Heckl Trust and Torsten Rempe
are each the record and beneficial owner of one percent (1%) of the outstanding
membership interest of Hetronic Holding. 
Except as set forth on Schedule 5.4.1, (i) Hetronic
Holding is the record and beneficial owner of all of the issued and outstanding
shares, capital stock, or other applicable equity or other proprietary
interests of Hetronic Deutschland, Hetronic Europe, Hetronic Malta and Hetronic
USA, and (ii) Hetronic USA is the record and beneficial owner of all of
the issued and outstanding shares, capital stock, or other applicable equity or
other proprietary interests of Hetronic West.

 

5.4.2.       Capitalization and Ownership
of Hetronic Asia.  The
authorized capital stock of Hetronic Asia consists of Eight Million Two Hundred
Fifty Thousand pesos (P8,250,000) in lawful money of the Philippines divided
into Eighty-Two Thousand Five Hundred (82,500) shares with the par value of One
Hundred Philippine pesos (P100) per share, of which Eighty-Two Thousand Five
Hundred (82,500) shares are issued and outstanding and constitute the Hetronic
Asia Shares.  Schedule 5.4.2
hereto sets forth each record and beneficial owner and holder of any shares of
the issued and outstanding stock of Hetronic Asia, together with the number of
shares held by each such holder.  There
are no Contracts relating to the issuance, sale, or transfer of any equity
securities or other securities of Hetronic Asia.  Without limitation to the foregoing, Hetronic
Asia has no outstanding subscriptions, options, warrants, rights or other
Contracts granting to any Person any interest in or right to acquire at any
time, or upon the happening of any stated event, any stock, equity securities
or other securities issued by or issuable by Hetronic Asia (including any
securities convertible into or exchangeable for any of the foregoing), or any
interest therein; or requiring Hetronic Asia to repurchase, reacquire, redeem
or retire any stock, equity securities or other securities. There are no
outstanding or authorized equity appreciation, phantom equity or similar rights
with respect to Hetronic Asia.  There are
no voting trusts, proxies or any other agreements or understandings with
respect to the voting of the stock of Hetronic Asia. Each Hetronic Asia
Shareholder has valid and marketable title to the Purchased Shares identified
as owned by such Hetronic Asia Shareholder, free and clear of all Liens. No
legend or other reference to any purported Liens appears upon any certificate
representing Hetronic Asia Shares. All of the Hetronic Asia Shares have been
duly authorized and validly issued and are fully paid and non-assessable. There
are no contracts relating to the issuance, sale, or transfer of any equity
securities or other securities of Hetronic Asia. None of the Hetronic Asia
Shares are issued in violation of any Law. There are no subscriptions, options,
warrants, rights or other agreements granting to any Person any interest in or
right to acquire from any of the Hetronic Asia Shareholders at any time, or
upon the happening of any stated event, any Hetronic Asia Shares or any
interest therein.

 

11

 

5.4.3.       Hetronic Asia Company
Matters.  True, correct and complete
copies of the Organizational Documentation, minute books and stock records of
Hetronic Asia have been furnished to Methode. 
Hetronic Asia has no Subsidiaries and Hetronic Asia does not own,
directly or indirectly, or have any Contract to acquire, any stocks, bonds or
securities or any equity or other proprietary interest in any corporation,
partnership, limited liability company, joint venture, business enterprise or
other entity of any nature whatsoever. Schedule 5.4.3 sets forth: (i) a
list of all accounts and deposit boxes maintained by Hetronic Asia at any bank
or other financial institution and the names of the individuals authorized to
effect transactions in such accounts and with access to such boxes; (ii) all
agreements or commitments of Hetronic Asia guaranteeing the payment of money or
the performance of other contracts by any other Person, and (iii) the
names of all Persons holding general or special powers of attorney from
Hetronic Asia, together with a summary of the terms thereof. Schedule 5.4.3
hereto sets forth the names and positions of each officer and director of
Hetronic Asia.

 

5.5.          Financial Statements.  Schedule 5.5 hereto contains true
and complete copies of the following financial statements (collectively, the “Financial
Statements”) (i) the unaudited consolidated balance sheets of the
Target Companies and Hetronic Deutschland, together with the related statements
of income at and for each of the three (3) consecutive fiscal years ended December 31,
2007; and (ii) the unaudited consolidated balance sheets of the Target
Companies and Hetronic Deutschland, together with the related statements of
income at and for the quarterly periods ended March 31, 2008 and June 30,
2008 (the “Interim Financial Statements”).

 

Except as disclosed on Schedule 5.5,
the Financial Statements: (i) were prepared in accordance with the books
of account and other financial records of the Target Companies and Hetronic
Deutschland, (ii) are accurate, correct and complete in all material
respects and fairly present the assets, Liabilities and financial condition of
the Target Companies and Hetronic Deutschland as at the respective dates
thereof, and the results of operations for the periods then ended, and (iii) have
been prepared on a consistent basis with the past practices of the Target
Companies and Hetronic Deutschland.

 

In addition, Schedule 5.5
hereto contains true and complete copies of the monthly management reports for
each monthly period completed since the date of the last Interim Financial
Statement and such management reports were prepared in accordance with the
books of account and other financial records of the Target Companies.

 

5.6.          Books and Records.  The books of account and other financial
records of the Target Companies, all of which have been made available to
Methode, are complete and correct in all material respects and represent
actual, bona fide transactions and have been maintained in accordance with
sound and customary business and accounting practices including the maintenance
of an adequate system of internal controls.

 

5.7.          No Undisclosed Liabilities.  Hetronic Asia does not have any Liabilities
of any nature whatsoever, whether arising out of contract, tort, statute or
otherwise, which are not reflected, reserved against or given effect to in the
Interim Financial Statements except: (a) Liabilities incurred in the
Ordinary Course of Business since the dates of the last Interim Financial
Statement, which are of the same nature as those set forth in the Interim
Financial Statements, and which are not, individually or in the aggregate,
material to Hetronic Asia, and 

 

12

 

(b) Liabilities which
are specifically disclosed in Schedule 5.7.  To Sellers’ Knowledge, there is no basis for
assertion against Hetronic Asia of any Liabilities not adequately reflected,
reserved against or given effect to in the Interim Financial Statements or in Schedule 5.7,
except for Liabilities described in clause (a) above.

 

5.8.          Absence of Certain Changes.  Except as disclosed in Schedule 5.8
or the Financial Statements, since December 31, 2007, the business and
operations of the Target Companies have been conducted in the ordinary course
consistent with past practices and, without limiting the foregoing, there has
not been:

 

(a)           any material adverse change
in the condition (financial or otherwise) of the properties, assets,
Liabilities or results of operation of the Target Companies, or any event,
occurrence, development, state of circumstances or facts that would reasonably
be expected to have, individually or in the aggregate, a Material Adverse
Effect;

 

(b)           any damage, destruction or
loss (whether or not covered by insurance) affecting the properties, assets,
Liabilities, financial condition, results of operations or business prospects
of the Target Companies that has had or would reasonably be expected to have,
individually or in the aggregate, a Material Adverse Effect;

 

(c)           any material labor dispute,
other than routine individual grievances, or any activity or proceeding by a
labor union or representative thereof to organize any employees of the Target
Companies, or any material lockouts, strikes, slowdowns, work stoppages or
threats thereof by or with respect to such employees;

 

(d)           any material change in the
customary methods of operations of the Target Companies, including practices
and policies relating to manufacturing, purchasing, Inventories, marketing,
selling and pricing;

 

(e)           any declaration, setting
aside, or payment of any dividend or other distribution, or any direct or
indirect redemption, retirement, purchase or other acquisition of any shares,
capital stock, or other applicable equity or other proprietary interests, or
any issuance of shares, capital stock, or other applicable equity or other
proprietary interests or the granting, issuance or exercise of any right,
warrant, option or similar commitment relating to any issued and outstanding
shares, capital stock, or other applicable equity or other proprietary
interests, other than cash dividends or cash distributions in accordance with
law;

 

(f)            any increase in the
compensation, benefits, commissions or perquisites payable or to become payable
by any Target Company to any director, officer, employee, or agent of any
Target Company, or any payment of or agreement to pay any bonus, profit sharing
or other extraordinary compensation to any employee of any Target Company
(other than any such increase or payment to Persons that were paid or that
become payable in the Ordinary Course of Business);

 

(g)           any establishment, adoption
or amendment of (i) a severance or termination pay plan or agreement for
any director, officer or employee of any Target Company, or any increase in
benefits payable under any existing severance or 

 

13

 

termination pay policies or employment agreements,
or (ii) any collective bargaining, bonus, profit-sharing, thrift, pension,
retirement, deferred compensation, compensation, stock option, restricted stock
or other benefit plan or arrangement covering any director, officer or employee
of any Target Company;

 

(h)           any material change in the
accounting methods or practices or in any method of tax accounting followed by
any Target Company or any change in depreciation or amortization policies or
rates theretofore adopted;

 

(i)            any material write-up or
write-down of the value of any Inventories or revaluation any assets of any
Target Company, other than in the Ordinary Course of Business;

 

(j)            any cancellation or release
of any Indebtedness owed to or Claims held by any Target Company;

 

(k)           any sale, lease, abandonment
or other disposition by any Target Company, other than in the Ordinary Course
of Business, of any machinery, equipment or other operating properties, or any
intangible assets owned, leased or licensed by any Target Company;

 

(l)            any incurrence, assumption
or guarantee by any Target Company of any Indebtedness;

 

(m)          any transaction or
commitment made, or any Contract entered into, by any Target Company pursuant
to which any property or assets of any Target Company is subjected to a Lien;

 

(n)           any making of any loan,
advance or capital contribution to, or investment in any Person;

 

(o)           any transaction or
commitment made, or any Contract entered into, by any Target Company relating
to any of its assets or business (including the acquisition or disposition of
any assets) or any relinquishment by any Target Company of any Contract or
other right, in either case, material to any Target Company, other than
transactions and commitments in the Ordinary Course of Business and those
contemplated by this Agreement;

 

(p)           any transaction or
commitment made, or any Contract entered into, by any Target Company pursuant
to which any Intellectual Property is disclosed to or licensed to any Person,
other than transactions and commitments in the Ordinary Course of Business;

 

(q)           any transaction or
commitment made, or any Contract entered into, by any Target Company with a
director or officer of any Target Company, any member of the immediate family
of any such Persons, or any Person controlled by any of the foregoing Persons;
or

 

14

 

(r)            any agreement or commitment
on the part of any Target Company to do any of the foregoing.

 

5.9.          Tax Matters.

 

5.9.1.       Filing of Tax Returns. All Tax
Returns required to be filed by the Target Companies through the date hereof
have been, and as to Tax Returns required to be filed through the Closing Date
will be, timely filed with the appropriate Governmental Authorities in all jurisdictions
in which such Tax Returns are required to be filed, in each case subject to
such extensions that have been properly obtained by the Target Companies. All
such Tax Returns are or will be true and correct and prepared in accordance
with applicable Law and properly reflect, or will properly reflect, the Taxes
of the Target Companies for the periods covered thereby. Copies of all income
tax returns for or in respect of each Target Company for all years not barred
by the statute of limitations have heretofore been delivered by the Target
Companies to Methode.

 

5.9.2.       Payment of Taxes. Except as set
forth on Schedule 5.9, all Taxes due and payable by the Target
Companies with respect to all periods prior to and through the date hereof have
been, and through the Closing Date will be, duly and properly computed,
reported, fully paid and discharged and there are no unpaid Taxes with respect
to any period prior to and through the date hereof, and there will not be any
unpaid Taxes with respect to any period through the Closing Date, which are or
could become a Lien on any Acquired Assets or the Purchased Shares, except for
current Taxes not yet due and payable.

 

5.9.3.       Assessments or
Investigations. None of the Target Companies has received any
notice of assessment or proposed assessment by the IRS or any other
Governmental Authority in connection with any Tax Returns and there are no
pending tax examinations of or tax claims asserted against any Target Company
or its properties.  No Target Company has
waived any statute of limitations in respect of Taxes or agreed to any
extension of time with respect to a Tax assessment or deficiency.  To Sellers’ Knowledge, there has been no
intentional disregard of any Law in the preparation of any Tax Return
applicable to any Target Company.  No
claim has ever been made by a Governmental Authority in a jurisdiction where a
Target Company does not pay Taxes or file Tax Returns that such Target Company
is or may be subject to Taxes assessed by such jurisdiction.

 

5.9.4.       Tax Liens. Except as
disclosed in Schedule 5.9, there are no Tax Liens on any of the
properties or assets of any Target Company, except for liens for current taxes
not yet due and payable and, to Sellers’ Knowledge, there is no basis for any
additional assessment of any Taxes with respect to any Target Company.  No Target Company has waived any Law fixing,
or consented to the extension of, any period of time for assessment of any
Taxes which waiver or consent is currently in effect.

 

5.9.5.       Withholding. Each Target
Company has withheld and paid all Taxes required to have been withheld and paid
in connection with amounts paid or due and owing to any employee, creditor,
independent contractor, or other third party and each Target Company has
properly reflected the status of all employees and independent contractors in
connection therewith as required by all applicable Laws.

 

15

 

5.9.6.       Other Tax Matters. No Target
Company is a party to, or bound by, any tax sharing, tax indemnity, tax
allocation or similar agreement or arrangement. 
No Target Company has ever been a member of an affiliated group within
the meaning of Section 1504 of the Code (or any similar group defined
under a similar provision of any state, local or foreign Law (an “Affiliated
Group”) filing a consolidated federal income Tax Return (other than the
Affiliated Group of which Hetronic Holding is the includible common parent) or
has ever incurred any Liability for the Taxes of any Person under Treas. Reg. Section 1.1502-6
(or any similar provision of any state, local, or foreign Law), as a transferee
or successor, by contract, or otherwise. No Target Company has: (i) filed
a consent under Code Sec. 341(f) concerning collapsible corporations; (ii) made
any payments and is not obligated to make any payments that will not be
deductible to any Target Company under Code Sec. 280G; or (iii) been a
United States real property holding corporation within the meaning of Code Sec.
897(c)(2) during the applicable period specified in Code Sec.
897(c)(1)(A)(ii).

 

5.10.        Title to Assets. The Target
Companies are the owners of and have good and marketable title to the Acquired
Assets, free and clear of Liens, except for: (i) the lien of current taxes
not yet due and payable, and (ii) Liens disclosed and described in Schedule 5.10
hereto.  Except as disclosed in Schedule 5.10,
the Acquired Assets are usable in the Ordinary Course of Business, are in
reasonable condition and repair and conform in all material respects to all applicable
Laws relating to their construction, use and operation. Except as disclosed in Schedule 5.10,
the Acquired Assets include all assets, properties and rights necessary to
conduct the business conducted by the Target Companies substantially in the manner
conducted since January 1, 2007 and all assets, properties and rights
owned by any of the Selling Parties or their Affiliates and used in the
business conducted by the Target Companies since January 1, 2007;
provided, however, that Hetronic Deutschland’s distribution and assembly
operation is an essential component of the business conducted by the Target
Companies, and none of such operations are being acquired because neither the
shares or assets of Hetronic Deutschland are included in the Acquired Assets.

 

5.11.        Real Estate and Leases. The Target
Companies do not own, and have not ever owned, any real estate. No Target
Company is a party to any oral lease or agreement under which any Target
Company is lessee of, or holds or operates, any real estate (including
buildings and improvements) (the “Leased Facilities”). Schedule 5.11
lists every written lease or agreement under which any Target Company is lessee
of, or holds or operates, any Leased Facility (each a “Facility Lease”).
True, correct and complete copies of all Facility Leases have been provided to
Methode.  Each Facility Lease is in full
force and effect and constitutes a legal, valid and binding obligation of the
respective parties thereto.  No Target
Company nor, to Sellers’ Knowledge, any other party thereto is in default in
any material respect under a Facility Lease nor, to Sellers’ Knowledge, has any
event occurred which with the passage of time or giving of notice or both would
constitute such a default.  Except as set
forth in Schedule 5.11, no modifications, alterations, improvements
or installations to a Leased Facility have been made which would permit the
landlord to require material expenditures by the tenant to place such Leased
Facility in conformance with requirements arising under or upon expiration or
termination of the Facility Lease therefor. Except as set forth in Schedule 5.11,
the present maintenance, operation, use and occupancy of the Leased Facilities
by the Target Companies does not violate any instrument of record or agreement
affecting such Leased Facilities or any Law, including any zoning, subdivision,
building, health, environmental, pollution, fire or similar 

 

16

 

Law and none of the Target
Companies have received any notices from any Governmental Authority in respect
to the Leased Facilities that have not been corrected (or are in the process of
being corrected and disclosed in Schedule 5.11) and all water, gas,
electrical, steam, compressed air, telecommunication, sanitary and storm sewage
lines and systems and other similar systems serving the Leased Facilities are
installed and operating and are sufficient to enable the Leased Facilities to
continue to be used and operated in the manner currently being used and operated,
and any so-called hook-up fees or other associated charges have been fully
paid.  To Sellers’ Knowledge, there is no
plan, study, or effort by any Governmental Authority or any non-governmental
Person or agency which may adversely affect the present use of the Leased
Facilities. No current use by any Target Company of the Leased Facilities or
improvement located thereon is dependent on a nonconforming use or other
approval from a Governmental Authority, the absence of which would
significantly limit the use of any of the properties or assets in the operation
of the Business. There are no pending condemnation proceedings with regard to
all or any part of the Leased Facilities and, to Sellers’ Knowledge, no such
proceedings are threatened or contemplated by any Governmental Authority.

 

5.12.        Material Contracts.  Except as set forth in Schedule 5.12,
no Target Company is a party to, or bound by, any Contracts:

 

(a)           for the sale of products
(including raw materials, commodities, supplies, or other personal property) or
for the furnishing of services, the performance of which will extend over a
period of more than one year, or that involves annual payments in excess of
$100,000 or which cannot be canceled by such Target Company without penalty or
further payment and without more than thirty (30) days prior notice;

 

(b)           for the purchase of products
or services involving payment of in excess of $100,000 per annum by a Target
Company or which cannot be canceled by such Target Company without penalty or
further payment and without more than thirty (30) days prior notice;

 

(c)           for leasing personal
property (including leases for office or computer equipment, furniture,
fixtures, and vehicles) which require an annual payment in excess of $100,000
or the term of which at any time exceeded one (1) year;

 

(d)           for the lease of real or
personal property to any Person;

 

(e)           constituting a partnership
or joint venture;

 

(f)            between such Target Company
and any Governmental Authority;

 

(g)           under which it has created,
incurred, assumed, or guaranteed any Indebtedness, or under which it has
imposed a Lien on any of its assets, tangible or intangible;

 

(h)           prohibiting such Target
Company from freely engaging in business (or in any line of business) anywhere
in the world or containing any other restrictive covenant or containing any
confidentiality or exclusivity clause or obligation; or requiring such Target
Company to engage in affirmative action; or otherwise materially restricting
the 

 

17

 

conduct of the business of such Target Company,
except to the extent such Contract is executed in connection with the
transactions contemplated hereby;

 

(i)            for the employment of any
individual on a full-time, part-time, consulting, or other basis providing
annual compensation in excess of $20,000 or which is not cancelable without
payment of severance and on fourteen (14) days’ notice or less, or any
severance agreement;

 

(j)            under which it has advanced
or loaned any amount to any of its directors, officers, and employees or
guaranteed any such loan;

 

(k)           for the purchase or sale of
capital stock membership interests or interests therein, or of securities
convertible into or exchangeable for capital stock;

 

(l)            providing for the services
of dealers, distributors, sales representatives or similar representatives;

 

(m)          relating to the ownership,
use or licensing of any Intellectual Property (provided, however, that
shrink-wrap licenses whereby such Target Company licenses generally-available
off-the-shelf software may be disclosed on Schedule 5.12 by listing
only the software name and number of licenses/seats purchased rather than by
listing individual licenses), including any current or past grant of, or
termination of any grant of, rights in the Target Company Intellectual
Property, any development of Target Company Intellectual Property by a third
party, or any transfer of rights in any Intellectual Property; or

 

(n)           which are otherwise material
to the Acquired Assets or Hetronic International or the business conducted by
the Target Companies utilizing the Acquired Assets.

 

Except as provided in Schedule 5.12,
each Contract to which any Target Company is a party: (i) is legal, valid
and binding on the respective parties thereto and is in full force, and (ii) upon
the consummation of the transactions contemplated by this Agreement shall
continue in full force and effect without penalty or adverse consequence.  No Target Company nor, to Sellers’ Knowledge,
any other party thereto, is in breach of, or default under the provisions of
any such Contract (except where such default is excused as immaterial and does
not give rise to any termination right or penalty under the terms of such
Contract).  True, correct and complete
copies of all written Contracts disclosed on Schedule 5.12 and
accurate descriptions of all oral Contracts disclosed on Schedule 5.12
have been provided to Methode.

 

5.13.        Receivables.  An aged list of all unpaid Receivables of the
Target Companies outstanding as of the most recent practicable date is attached
on Schedule 5.13 hereto. 
Except as disclosed on Schedule 5.13, all Receivables of the
Target Companies, net of any reserves for doubtful accounts, arose from sales
in the Ordinary Course of Business, represent legal and valid obligations to
the applicable Target Company and are good and collectible in the Ordinary
Course of Business within the period specified on Schedule 5.13 and
are not subject to any reduction or discount that has been agreed to by any
Target Company or, to Sellers’ Knowledge, any dispute, counterclaim, Lien or
set-off.

 

18

 

5.14.        Inventories.  All Inventories of the Target Companies
reflected on the balance sheet contained in the Interim Financial Statements or
acquired since the dates thereof, net of reserves, consist of items of a
quality and quantity usable and salable in the Ordinary Course of Business as
first quality goods (subject to claims under the Assumed Warranties).  Each item of Inventory reflected on the Financial
Statements and the books and records of the Target Companies is valued at cost,
provided that each item of Inventory reflected on the Financial Statements and
the books and records of Hetronic Malta is valued at the lower of cost or
market.  Each Target Company has, and on
the Closing Date will have, sufficient amounts of Inventory to conduct its
business and such amounts are consistent with its past practices.

 

5.15.        Litigation.  Except as disclosed in Schedule 5.15,
there are no actions, suits, inquiries, proceedings, claims or investigations
by or before any Governmental Authority pending or, to Sellers’ Knowledge,
threatened against, or involving, the Acquired Assets, the Purchased Shares,
the Target Companies, any of their properties, assets or businesses, or any
officers or directors of the Target Companies, and, to Sellers’ Knowledge,
there is no basis for any such action. 
Except as set forth in Schedule 5.15, there are no
judgments, consents, decrees, injunctions, or any other judicial or administrative
mandates outstanding against any Target Company.

 

5.16.        Insurance.  Schedule 5.16 contains a
description of all insurance policies maintained by or on behalf of any Target
Company on its properties, assets, business or personnel, in each case specifying
(i) the insurer, (ii) the amount of coverage, (iii) the type of
insurance, (iv) the policy number, and (v) any currently pending
claims thereunder or any claims asserted thereunder or under similar policies
since January 1, 2007.  All such
policies are (and pending Closing will continue to be) in full force and
effect, and no Target Company is in default in any material respect with
respect to any provision contained in any insurance policies, and, to Sellers’
Knowledge, no event has occurred that, with notice or lapse of time, could
constitute such a default or permit termination of the policy.  No Target Company has failed to give any
notice or present any claim under any such policy in due and timely fashion.  To the extent that any Contract to which any
Target Company is a party requires any Target Company to maintain a specified
level of insurance coverage, such Target Company maintains such required
insurance coverage in accordance with such Contract.

 

5.17.        Employment and
Labor Matters.

 

5.17.1.     Employees. Schedule 5.17
hereof contains a list of the names of each employee of each Target Company
employed at any time since January 1, 2008, together with their current
employment status, annual salary, bonuses and perquisites and their total compensation
during the fiscal year ended December 31, 2007.

 

5.17.2.     Collective Bargaining
Agreements. Except as disclosed on Schedule 5.17,
no Target Company is a party to or otherwise bound by any contract, agreement
or collective bargaining agreement with any labor union or organization or
other commitment respecting employment or compensation of any of its officers,
directors, agents or employees, and no employees of any Target Company are
represented by any labor union, workers council or similar organization.

 

19

 

5.17.3.     Employee Claims.  There are no charges or complaints involving
any federal, state or local civil rights enforcement agency, court or other
Governmental Authority; complaints or citations under the Occupational Safety
and Health Act or any state or local occupational safety act or regulation;
unfair labor practice charges or complaints with any Governmental Authority
with jurisdiction over labor- or employment-related claims (including the United
States National Labor Relations Board); or other claims, charges, actions or
controversies pending, or, to Sellers’ Knowledge, threatened or proposed,
involving any Target Company and any employee, former employee or any labor
union or other organization representing or claiming to represent such
employees’ interests.

 

5.17.4.     Compliance.  Each Target Company is and has heretofore
been in compliance with all Laws respecting employment and employment
practices, terms and conditions of employment and wages and hours, the
sponsorship, maintenance, administration and operation of (or the participation
of its employees in) employee benefit plans and arrangements and occupational
safety and health programs, and no Target Company is engaged in any violation of
any Law related to employment, including unfair labor practices or acts of
employment discrimination.

 

5.18.        Employee
Benefits.

 

5.18.1.     Identification. Schedule 5.18 contains a true and
complete list of all Employee Plans, whether express or implied, applicable to
any employees or former employees of any Target Company and true and correct
copies of such Employee Plans have been furnished to Methode.  True and correct copies of all employee
manuals or written statements of policy relating to the employment of employees
of Target Companies, if any, have been furnished to Buyer. Without limitation
to the foregoing, except as disclosed in Schedule 5.18, (i) no
Target Company maintains or contributes to, nor has any Target Company at any
time maintained or contributed to, a “defined benefit plan” within the meaning
of Section 3(35) of ERISA, (ii) no Target Company maintains or has
had an obligation to contribute to any multiemployer plan (within the meaning
of Section 3(37) of ERISA), and (iii) no Target Company maintains any
Welfare Plan.

 

5.18.2.     Compliance. Each Employee Plan and each related trust, insurance contract or fund
maintained by, or contributed to, by any Target Company has complied in form
and operation with all filings, reporting, disclosure and other requirements of
ERISA and, to the extent applicable, the Code. No Selling Party or Target
Company has received any notice to correct any violation of any applicable Laws
relating to any Employee Plans of any Target
Company or the manner in which
they are administered, with which it has not complied; and the provisions and
operations of all such plans, programs and policies are in substantial
compliance with applicable Laws. All required reports and descriptions
(including Form 5500 annual reports, summary annual reports, PBGC-1’s, and
summary plan descriptions) have been timely filed or distributed appropriately
with respect to each Employee Plan. 
Neither the Target Companies nor any of their members, managers,
officers or directors has engaged in any transaction in violation of the
prohibited transactions provisions set forth in Section 4975 of the Code
or Section 406 of ERISA, which would be reasonably likely to result in
liability to any such party.  The
requirements of COBRA have been met with respect to each Welfare Plan.  All contributions (including employer
contributions and employee salary reduction contributions) which are due

 

20

 

have been paid to each
Pension Plan. All premiums or other payments for all periods ending on or
before the Closing Date have been paid with respect to each Welfare Plan.  No Target Company has incurred, or taken any
actions that could cause it to occur, a “complete withdrawal” or “partial
withdrawal”, as defined in Sections 4203(a) and 4205(a), respectively, of
ERISA, from any multiemployer pension plan as to which any Target Company
contributes, has contributed or has had an obligation to contribute.  No Selling Party or Target Company has
received from the sponsor of a multiemployer pension plan any notice of, or any
notice relating to, withdrawal liability under Part 1 of Subtitle E of
Title IV of ERISA relating to such plan. There is no litigation or filed claims
against any Target Company with respect to any Employee Plan other than routine
claims for benefits.

 

5.18.3.     Funding of Certain Plans. There is no Employee Plan that is a Welfare Plan, the benefits under
which are not provided exclusively from the assets of the Target Companies or
through insurance contracts. The financial and actuarial statements, if any,
for each Employee Plan reflect in all material respects the financial condition
and funding of the Employee Plans as of the date of such financial and
actuarial statements, and no change has occurred with respect to the financial
condition or funding of the Employee Plans since the date of such financial and
actuarial statements.

 

5.18.4.     Acceleration of Payments. The consummation of the transactions contemplated by this Agreement
will not (i) entitle any current or former employee, director or officer
of any Target Company to severance pay, unemployment compensation or any other
payment, (ii) accelerate the time of payment or vesting, or increase the
amount of compensation due any such employee, director or officer, or trigger
the funding (through a grantor trust or otherwise) of compensation or benefits
under, increase the amount payable or trigger any other material obligation
pursuant to, any or any other agreement; or (iii) result in any breach or
violation of, or a default under, any Employee Plan.

 

5.19.        Intellectual
Property.

 

5.19.1.     Identification of
Intellectual Property.  The
Target Companies own or have the right to use, with the right to license or
sublicense, all Intellectual Property necessary to conduct their business as
now conducted.  Schedule 5.19
hereto lists and identifies correctly and completely (with patent numbers,
registration numbers or application numbers, as applicable) the current
interests of each Target Company in all registrations for or applications to
register Intellectual Property, lists all invention disclosures submitted by
any personnel of any Target Company (for which a patent application has not
been filed), and lists and generally identifies the current interests of each
Target Company in all other Target Company Intellectual Property. With respect
to any licenses, sublicenses, franchise agreements or similar types of
agreements concerning Target Company Intellectual Property, Schedule 5.19
includes the identity of all parties thereto, a description of the nature and
subject matter thereof, the applicable royalty, the exclusivity or
non-exclusivity thereof and the term thereof.

 

5.19.2.     Title to Intellectual
Property.  No other
Person holds any right, Lien or other interest not specified in Schedule 5.19,
or has any right to a royalty or payment of any kind from any Target Company,
with respect to the Target Company Intellectual Property.  Except as indicated in Schedule 5.19,
there has been no asserted claims or litigation challenging or 

 

21

 

threatening to challenge the
right, title and interest of any Target Company to use the Target Company
Intellectual Property, and to Sellers’ Knowledge, there is no bases for any
such claims.  No Target Company
Intellectual Property is subject to any outstanding judgment, injunction,
order, decree, or agreement restricting the use thereof by any Target Company
or restricting the licensing or transfer thereof by any Target Company.

 

5.19.3.     No Infringement by Target
Companies. The operation of the business of the Target
Companies and the ownership, manufacture, purchase, sale, licensing and use of
any of the Target Company Intellectual Property do not contravene, conflict
with, violate or infringe upon any Intellectual Property of any third party and
no Trade Secret has been misappropriated by any Target Company from any third
party.  In addition, the use, licensing
or sale by or to each Target Company of any of the Target Company Intellectual
Property does not require the acquiescence, agreement or consent of any third
party that has not been obtained. The operations and business of each Target
Company do not violate any rights of others in any of the items set forth in Schedule 5.19
and no further rights or licenses with respect to Intellectual Property are
required by any Target Company for the conduct of the business as now being
conducted by it.

 

5.19.4.     Infringement by Third
Parties. To Sellers’ Knowledge, no right of any Target Company with respect to
the Target Company Intellectual Property is being violated or infringed by
others.  Except as described in Schedule 5.19,
the Target Company Intellectual Property and the Target Companies’ products are
not subject to any pending or, to Sellers’ Knowledge, any threatened challenge
or claim of infringement, interference or unfair competition.

 

5.19.5.     Registrations for
Intellectual Property. 
Except as set forth on Schedule 5.19, all patents, trademark
registrations, applications for trademark registration, copyright registrations
and applications for copyright registration with respect to any Target Company
Intellectual Property Right: (i) are in compliance with all formal legal
requirements and are not subject to any maintenance fees or taxes or actions,
the deadline for which falls due prior to the Closing Date or within thirty
days after the Closing Date; or (ii) are not subject to any pending or, to
Sellers’ Knowledge, any threatened action in which a third party seeks to
cancel, invalidate or oppose any right arising therefrom or has otherwise
contested the validity, enforceability, or ownership thereof.

 

5.19.6.     Trade Secrets. With respect
to each Trade Secret owned by, licensed by or used by a Target Company
(including all technical information, vendor lists, specifications and
requirements and other Trade Secrets relating to the development processes,
software and activities of each Target Company), the documentation maintained
by each Target Company relating thereto is reasonably current, accurate, and
sufficient in detail and content to identify and allow its full and proper
use.  Each Target Company has exercised
at least a reasonable degree of care in protecting the secrecy of all Trade
Secrets owned by, licensed by or used by each Target Company and, to Sellers’
Knowledge, no Trade Secret used by any Target Company has been divulged to any
third party without obligation to maintain the confidentiality thereof.

 

5.19.7.     Employee Developments. Except as
described in Schedule 5.19, all current employees of each Target
Company involved in the development of Intellectual Property have executed
written agreements assigning to such Target Company all right, title and
interest 

 

22

 

in Intellectual Property
developed by such employees as part of their employment activities (“Employee
IP Agreements”).  True and correct
copies of the Employee IP Agreements of current and, to the extent available,
former employees have been provided to Methode prior to the Closing Date.  Except as described in Schedule 5.19,
neither any Target Company nor, to Sellers’ Knowledge, any current or former
employee of any Target Company is in breach of, or default under the provisions
of any such agreement. Except as described in Schedule 5.19, no
former employee of a Target Company who developed any material Target Company
Intellectual Property has failed to assign to such Target Company all right,
title and interest in such Target Company Intellectual Property.  To Sellers’ Knowledge, no current employee of
any Target Company has entered into any written agreement with a third party
which restricts or limits in any way the scope or type of work that such employee
may perform for any Target Company.

 

5.19.8.     No Contravention. The
consummation of the transactions contemplated by this Agreement will not alter
or impair any of the rights of any Buyer after the Closing to use the Target
Company Intellectual Property in the manner used by the Target Companies prior
to the Closing.

 

5.20.        Legal Compliance.  Except as disclosed in Schedule 5.20,
each Target Company has complied with and is in compliance with all Laws
applicable to it (including Laws applicable to immigration, controls, wages and
hours, civil rights, occupational health and safety, and competition), has
complied with ethical business practices in the conduct of its business, and
has not received any notice of claimed noncompliance with any Laws or ethical
business practices. Without limitation to the foregoing, no Target Company has,
nor, have any employees, officers, directors, consultants, advisors, agents,
members or representatives of any Target Company or other Person acting on
behalf of any Target Company, violated, or taken any action which would cause
any Target Company to be in violation of, the Foreign Corrupt Practices Act of
1977, as amended (the “FCPA”), or the USA Patriot Act, or any rules and
regulations thereunder.  There is not
now, and there has never been, any employment by any Target Company of, or
beneficial ownership in any Target Company by, any governmental or political
official of any country.

 

5.21.        Approvals. Except as
described in Schedule 5.21, each Target Company possesses or has
applied for all governmental and other permits, licenses, consents,
certificates, orders, authorizations and approvals (the “Approvals”) to
own or hold under lease and operate its properties and assets and to carry on
its business as now conducted and all such Approvals are identified in Schedule 5.21.  Each Approval is valid, binding and in full
force and effect and each Target Company has complied with all requirements of,
and is not in default under, any such Approval and has not received any notice
that it is in violation of any of the terms or conditions of such Approval or
any notice relating to the revocation or modification of any such Approvals. No
loss or expiration of any Approval is threatened or pending other than
expiration in accordance with the terms thereof.

 

5.22.        Transactions with Affiliates.  Except as described in Schedule 5.22
and except for the sale of goods and services and licensing of Intellectual
Property among the Target Companies in the Ordinary Course of Business and/or
between the Target Companies and Hetronic Deutschland in the Ordinary Course of
Business, none of the Target Companies, their Affiliates, nor any officer or
director of any Target Company or its Affiliates, nor any member of the
immediate family of any such Persons: (a) has any direct or indirect
interest in (i) any 

 

23

 

property or asset which is
owned or used by any Target Company in the conduct of its business, or (ii) any
entity which does business with any Target Company; or (b) has any
financial, business or contractual relationship or arrangement with any Target
Company, has any outstanding loans to or from any Target Company, performs
services or supplies goods to any Target Company, or has any other Liabilities
due to or from any Target Company.

 

5.23.        Environmental
Matters.

 

5.23.1.     Environmental Compliance.  Except as disclosed in Schedule 5.23,
all facilities owned, leased, used or operated by any Target Company or any
predecessor in interest have been, and continue to be, owned, leased, used or
operated in compliance with all applicable Environmental Laws and all
Environmental Permits. All past non-compliance with Environmental Laws or
Environmental Permits has been resolved without any pending, on-going or future
obligation, cost or Liability, and there is no requirement proposed for
adoption or implementation under any Environmental Law or Environmental Permit.

 

5.23.2.     Environmental Audits.  Schedule 5.23 identifies (i) all
environmental audits, assessments, occupational health studies or similar
studies or analyses undertaken by, or at the direction of, Governmental
Authorities, any Target Company, or any predecessor in interest; (ii) the
results of the most recent analyses of water (including groundwater analyses),
soil, air or asbestos samples where non-compliance or contamination is
indicated; (iii) the most recent inspection of each operating facility by
the U.S. Environmental Protection Agency or other relevant Governmental
Authority; (iv) written communications with Governmental Authorities
relating to issues of noncompliance concerning Environmental Laws or
Environmental Permits; and (v) any written claim or complaint concerning
environmental matters of any Target Company, in each case relating to the real
property owned, leased or occupied by any Target Company, or any Target Company’s
operations, as applicable.

 

5.23.3.     Release, Storage or Disposal
of Hazardous Materials. 
Hazardous Materials have not been Released by any Target Company on any real
property owned, leased or occupied by any Target Company or, during its period
of ownership, lease or occupancy, on any property formerly owned, leased or
occupied by, or on behalf of, any Target Company.  Each Target Company has reported promptly to appropriate
authorities each unauthorized Release of any Hazardous Material at any facility
leased, owned, used or operated by any Target Company, or any predecessor in
interest, which was required to be reported by Target Companies under
applicable Environmental Laws.  Except as
disclosed in Schedule 5.23, no real property currently or formerly
owned, leased or occupied by any Target Company, and no site or location used
by any Target Company or any predecessor in interest has disposed, treated, or
arranged for the storage, disposal or treatment of, any Hazardous Material or
other waste (i) has been placed on the National Priorities List or its
state equivalent; (ii) the U.S. Environmental Protection Agency or other
relevant Governmental Authority has proposed, or is proposing, to place on the
National Priorities List or state equivalent; (iii) is on notice of, or
subject to a claim, administrative order or other demand either to take
Remedial Action or to reimburse any Person who has taken Remedial Action in
connection with that site; (iv) has filed (or has had filed with respect
to it) notification of hazardous waste activities; or (v) is on any state
Comprehensive Environmental Response Compensation Liability Information System
List or equivalent list.

 

24

 

5.23.4.     Remedial Actions.  No Target Company is conducting, nor has
undertaken or completed, any Remedial Action relating to any Release or
threatened Release of Hazardous Materials at real property owned, leased or
occupied by any Target Company or at any other site, location or operation,
either voluntarily or pursuant to the order of any Governmental Authority or
the requirements of any Environmental Law or Environmental Permit. Neither the
execution of this Agreement nor the consummation of the transactions
contemplated hereby will require any Remedial Action or notice to or consent of
Governmental Authorities or any third party pursuant to any applicable
Environmental Law or Environmental Permit.

 

5.23.5.     Storage Tanks.  Except as set forth in Schedule 5.23,
no Target Company has owned or operated, nor presently owns or operates, any
underground or aboveground storage tanks. 
To Sellers’ Knowledge, there are no underground or aboveground storage
tanks or any surface impoundments, septic tanks, pits, lagoons or other areas
in which Hazardous Materials are being or have been treated, stored or disposed
on any real property owned, leased or occupied by any Target Company. To
Sellers’ Knowledge, there are no wastes, drums or containers disposed of or
buried on, in or under the ground located on the premises owned or operated by
any Target Company.  No Target Company
has disposed of or buried any wastes, drums or containers on, in or under the
ground or any surface waters located on the premises owned or operated by any
Target Company.  No Target Company nor
any party acting on its behalf, has disposed of or buried, or arranged to
dispose of or bury, any waste, drums or containers in or on the premises of a
third party other than those pursuant to and in compliance with all applicable
Environmental Laws.

 

5.23.6.     Contaminants.  Except as set forth in Schedule 5.23,
there are no polychlorinated biphenyls, asbestos or asbestos-containing
materials or urea formaldehyde in or on premises owned or operated by any
Target Company and the soil, surface water and ground water at, under or on
each such premises are free from any material or substance which is or may be
hazardous or toxic, or which could otherwise pose a risk to health, safety or
the environment or which is regulated, prohibited or controlled pursuant to or
the subject of any Environmental Laws.

 

5.23.7.     Environmental Claims.  There are no Environmental Claims pending or
threatened against any Target Company and, to Sellers’ Knowledge, there are no
circumstances that can reasonably be expected to form the basis of any such
Environmental Claim, including with respect to any off-site disposal location
currently or formerly used by, or on behalf of, any Target Company or any of
its predecessors or with respect to any facilities previously owned, leased or
occupied by any Target Company.

 

5.24.        Product Liability and
Warranty Matters.  Except as
disclosed in Schedule 5.24, there are no actions, suits, inquiries,
proceedings, claims, or investigations by or before any Governmental Authority
pending or, to Sellers’ Knowledge, threatened, against or involving any Target
Company relating to any product alleged to have been manufactured or sold by
any Target Company and alleged to have been defective or improperly designed or
manufactured.  Schedule 5.24
lists all formal or informal policies, practices of Target Companies pursuant
to which any Person has any right to return any product or products sold by any
Target Company for credit or refund and any other express or implied
warranties, indemnifications or guarantees with respect to such products
(collectively, “Hetronic Warranties”). 
Except as disclosed in 

 

25

 

Schedule 5.24, no customer
of any Target Company has returned any products sold in the Business or applied
for or requested any credit or refund with respect thereto except pursuant to
said Hetronic Warranties.  Correct and
complete copies of all written Hetronic Warranties disclosed on Schedule 5.24
and accurate descriptions of all oral or informal Hetronic Warranties disclosed
on the Schedule 5.24 have been provided to Buyer.

 

5.25.        Principal Customers and
Suppliers.  Schedule 5.25
sets forth separate lists of the ten (10) largest
customers of the Target Companies (collectively) in terms of sales during the
years ended December 31, 2005, 2006 and 2007 (the “Named Customers”),
and the ten (10) largest suppliers to the Target Companies (collectively)
during the years ended December 31, 2005, 2006 and 2007 (the “Named
Suppliers”), showing in each case the approximate total sales and purchases
by or from each such customer or supplier during such period. There are no
other customers or suppliers who accounted for more than 5% of sales or
purchases, respectively, by the Target Companies during the periods shown.

 

Except as set forth on Schedule 5.25,
since January 1, 2008, no Named Customer or Named Supplier has terminated
its business relationship with the Target Companies or provided written notice
of its intent to refrain from purchasing from or dealing with the Target
Companies or, after the Closing, the Buyers. 
To Sellers’ Knowledge, there has not otherwise been any material adverse
change in the business relationship of any Target Company with any such Named
Customer or Named Supplier.

 

5.26.        Solvency.  No Target Company is, nor will any Target
Company be rendered by the occurrence of the transactions contemplated by this
Agreement, insolvent and, immediately after giving effect to the consummation
of the transactions contemplated by this Agreement each Target Company will be
able to pay its debts as they become due. 
As used herein, the term: (i) “insolvent” means that the sum of the
present fair salable value of its assets does not and will not exceed its debts
and other probable liabilities, and (ii) “debts” includes any legal
liability, whether matured or unmatured, liquidated or unliquidated, absolute,
fixed or contingent, disputed or undisputed or secured or unsecured.

 

5.27.        Material Adverse Affect. Since December 31,
2007, there has not been any material adverse change in the liabilities,
properties, customer
relationships, prospects, assets, results of operation or financial condition
of any Target Company, taken as a whole, and no event has occurred or
circumstance exists that may result in such a material adverse change.

 

5.28.        Disclosure.  No representation or warranty of the Selling
Parties made hereunder or in the schedules contains any untrue statement of a material
fact or omits to state a material fact necessary in order to make the
statements contained herein or therein not misleading.  Copies of all documents referred to herein or
in the schedules have been delivered or made available to Methode, are true,
correct and complete copies thereof, and include all amendments, supplements or
modifications thereto or waivers thereunder.

 

6.             REPRESENTATIONS AND
WARRANTIES OF METHODE.

 

As an inducement for the
Selling Parties to enter into this Agreement, Methode represents and warrants
to the Selling Parties as follows:

 

26

 

6.1.          Organization.  Methode and each of the Buyers is an
organization of the nature identified in Schedule 6.1 and is duly
organized, validly existing and in good standing under the laws of the
jurisdiction identified in Schedule 6.1.  Each Buyer has all requisite power and
authority to acquire the Purchased Assets and the Purchased Shares as
contemplated hereby.

 

6.2.          Enforceability
and Authorization.

 

6.2.1.       Authorization by Methode.  Methode has all requisite corporate power and
authority to execute and deliver this Agreement and all other agreements and
documents to be executed and delivered by Methode pursuant this Agreement and
to consummate the transactions contemplated hereby.  The execution and delivery of this Agreement
and all other agreements and documents to be executed and delivered by Methode
pursuant hereto, and the consummation of the transactions contemplated hereby
and thereby have been duly authorized by all necessary action on behalf of
Methode.  This Agreement constitutes, and
all other agreements and documents to be executed and delivered by Methode will
constitute, the valid and binding agreements of Methode, enforceable against
Methode in accordance with their respective terms, except that (i) such
enforcement may be subject to applicable bankruptcy, insolvency,
reorganization, moratorium or other similar Laws, now or hereafter in effect,
affecting creditors’ rights generally, and (ii) the remedy of specific
performance and injunctive and other forms of equitable relief may be subject
to equitable defenses and to the discretion of the court before which any
proceeding therefor may be brought.

 

6.2.2.       Authorization by the Buyers.  Each Buyer has or will have all requisite
corporate power and authority to execute and deliver all agreements and
documents to be executed and delivered by such Buyer pursuant this Agreement
and to consummate the transactions contemplated hereby.  The execution and delivery of all agreements
and documents to be executed and delivered by each Buyer pursuant hereto, and
the consummation of the transactions contemplated hereby and thereby have been
or will be duly authorized by all necessary action on behalf of the Buyer.  This Agreement constitutes, and all other
agreements and documents to be executed and delivered by each Buyer will
constitute, the valid and binding agreements of such Buyer, enforceable against
such Buyer in accordance with their respective terms, except that (i) such
enforcement may be subject to applicable bankruptcy, insolvency,
reorganization, moratorium or other similar Laws, now or hereafter in effect,
affecting creditors’ rights generally, and (ii) the remedy of specific
performance and injunctive and other forms of equitable relief may be subject
to equitable defenses and to the discretion of the court before which any
proceeding therefor may be brought.

 

6.3.          No Conflict; Methode
Consents.  Neither the
execution and delivery of this Agreement by Methode, nor the execution and
delivery by Methode and/or the Buyers of any other agreement or document to be
executed and delivered by Methode and/or the Buyers pursuant to this Agreement,
nor the consummation by Methode and/or the Buyers of the transactions
contemplated hereby or thereby will constitute a violation of, or be in
conflict with, or result in a cancellation of, or constitute a default under: (a) any
term or provision of the certificate of incorporation or bylaws of Methode or
such Buyer; (b) any judgment, decree, order, regulation or rule of
any court or other Governmental Authority to which Methode or such Buyer is
subject; (c) any applicable Law; (d) any Contract to which Methode or
such Buyer is a party or is bound.

 

27

 

Except as set forth on Schedule 6.3,
no consent of, or notice to, or filing with any Governmental Authority or any
other Person, is required to be obtained or given by Methode or any Buyer in
connection with the execution, delivery or performance of this Agreement or any
other agreement or document to be executed, delivered or performed hereunder by
the Methode or the Buyers.

 

7.             INTENTIONALLY OMITTED.

 

8.             CONDITIONS TO CLOSING.

 

8.1.          Mutual Conditions.  The respective obligations of each party to
consummate the transactions contemplated by this Agreement shall be subject to
the fulfillment at or prior to Closing of each of the following conditions:

 

8.1.1.       No Suit.  No suit, action or other proceeding or
investigation shall to the knowledge of any party to this Agreement be
threatened or pending before or by any Governmental Agency or by any third
party restraining or prohibiting the consummation of the transactions
contemplated by this Agreement.

 

8.2.          Conditions to Methode’s
Obligations.  The
obligations of Methode to consummate the transactions contemplated by this
Agreement shall be subject to the fulfillment at or prior to Closing of each of
the following conditions:

 

8.2.1.       Intentionally Omitted.

 

8.2.2.       Intentionally Omitted.

 

8.2.3.       Required Consents and
Approvals.  All
material authorizations, consents, waivers, approvals or other action
identified in Schedule 8.2.3, shall have been obtained.

 

8.2.4.       No Material Adverse Effect.  There shall have occurred no Material Adverse
Effect (whether or not covered by insurance).

 

8.2.5.       Payoff Letters.  The Selling Parties shall have delivered to
Methode payoff letters (the “Payoff Letters”) for all outstanding
Indebtedness of the Sellers secured by any Lien and for all outstanding
Indebtedness of Hetronic Asia (whether secured or unsecured), in each case in
form and substance acceptable to Methode, in its sole discretion.  Except for such releases and UCC termination
statements covered by such pay-off letters, the Target Companies shall have
obtained all releases and authorization to file all UCC termination statements
necessary to cause its properties and assets to be free and clear of all Liens
as of the Closing Date.  Notwithstanding
anything herein to the contrary, this condition shall only be satisfied if such
Payoff Letters specify an aggregate payoff amount less than the Closing Payment
minus the funds to be deposited in the Indemnity Escrow Account and Net Book
Value Escrow Account.

 

8.2.6.       Employment Agreements.  Torsten Rempe shall have entered into an
Employment Agreement with a Buyer in the form attached hereto as Exhibit B,
and such 

 

28

 

Employment Agreement shall
not have been amended, cancelled, terminated or otherwise modified.

 

8.2.7.       Ampcontrol Agreement.  Ampcontrol, Inc. shall have executed and
delivered to Methode a Supply Agreement in the form attached hereto as Exhibit C
(the “Ampcontrol Agreement”).

 

8.2.8.       German Distribution
Agreements.  Hetronic
Deutschland shall have executed and delivered to Methode a Distribution and
Assembling Partner Agreement and a License Agreement in the forms attached
hereto as Exhibit D (together, the “German Distribution
Agreements”).

 

8.2.9.       Consulting Agreement. The Shareholder
shall have executed and delivered to Methode a Consulting Agreement in the form
attached hereto as Exhibit E (the “Consulting Agreement”).

 

8.2.10.     Noncompetition Agreement.  Each Seller and the Shareholder shall have
executed and delivered to Methode a Noncompetition and Confidentiality
Agreement in favor of Methode and the Buyers in the form attached hereto as Exhibit F.

 

8.2.11.     Foreign Counsel Opinion. Local counsel
to Hetronic Asia shall have delivered to Methode an opinion of counsel, dated
the Closing Date, in the form attached hereto as Exhibit G.

 

8.2.12.     Escrow Agreement. The Selling
Parties and the Escrow Agent shall have executed and delivered to Methode an
Escrow Agreement in the form attached hereto as Exhibit H (the “Escrow
Agreement”).

 

8.2.13.     Lease Addendum. J &
G-Estates, L.L.C., an Oklahoma limited liability company, and Hetronic
International shall have executed and delivered to Methode a Lease Addendum in
the form attached hereto as Exhibit I (the “Lease Addendum”).

 

8.2.14.     Closing Documents.  The following documents shall have been
delivered to Methode:

 

(a)           Instruments of Assignment
for Purchased Assets.  Bills of
sale, deeds and other documents or instruments transferring, assigning and
conveying to the applicable Buyer designated by Methode all right, title and
interest in the Purchased Assets, free and clear of all Liens, duly executed by
the Sellers, all of which documents shall be in form and substance acceptable
to Methode, acting reasonably.

 

(b)           Name Change Documentation. Such
instruments and other documentation necessary to change the legal name of each
Seller to remove the word “Hetronic” from such legal name, executed by such
Persons and in such form ready for filing with the appropriate Governmental
Authority in each such Person’s jurisdiction of organization (the “Name
Change Filings”).

 

29

 

(c)           Good Standing Certificates.  Certificates of legal existence and good
standing for each Target Company issued as of a recent date prior to the
Closing Date by the Secretaries of State or other applicable Governmental
Authority of each jurisdiction in which such Target Company is organized or
qualified to do business.

 

(d)           Secretaries’ Certificates.  A certificate of the Secretary of each
Selling Party (other than the Shareholder) dated as of the Closing Date
certifying (i) that the existence and good standing such Selling Party has
not changed since the date of the certificates of legal existence and good
standing delivered to Methode, (ii) the resolutions of the applicable
management or supervisory board for such Selling Party authorizing the
execution, delivery and performance of this Agreement and/or all other
agreements, instruments, certificates and documents executed by such Person in
connection herewith, and (iii) the incumbency of the officers of such
Selling Party executing and delivering this Agreement and/or all other
agreements, instruments, certificates and documents executed by such Selling
Party in connection herewith.

 

8.2.15.     Hetronic Asia Closing
Deliveries.

 

(a)           Stock Certificates and
Instruments of Assignment for Purchased Shares. Hetronic Holding shall
have delivered to Methode the original share certificates representing the
Purchased Shares, duly endorsed in favor of the Buyer designated by Methode or
accompanied by instruments of assignment or such other documentation necessary
to convey to a Buyer designated by Methode all right, title and interest in the
Purchased Shares.

 

(b)           Secretary Certificate. The Secretary
of Hetronic Asia shall have delivered a certificate dated as of the Closing
Date certifying (i) that the existence and good standing Hetronic Asia has
not changed since the date of the certificates of legal existence and good
standing delivered to Methode, (ii) a copy of current Organizational
Documentation, with all amendments, in force as of such date, and (iii) the
incumbency of all directors and officers of Hetronic Asia.

 

(c)           Intercompany Agreement
Termination Documents. The Selling Parties and their Affiliates,
as applicable, shall have executed and delivered to Methode such agreements as
may be necessary to terminate the agreements between the Selling Parties and
their Affiliates and Hetronic Asia, in each case without further liability to
Hetronic Asia or the Selling Parties (the “Intercompany Agreement
Termination Documents”).

 

8.2.16.     German Local Transfer
Agreement. Hetronic Europe shall have executed and delivered
to Methode a Local Transfer Agreement in the form attached hereto as Exhibit K
(the “German Local Transfer Agreement”).

 

8.2.17.     Hetronic Deutschland
Intercompany Assignments. Hetronic Deutschland shall have executed
and delivered to Methode the bills of sale and instruments of assignment in the
form attached hereto as Exhibit L (the “Hetronic Deutschland
Intercompany Assignments”) conveying to Hetronic International, on a date
prior to the date of this Agreement, all rights in the Purchased Assets
identified therein (consisting of Trademarks previously assigned by

 

30

 

Hetronic Deutschland to
Hetronic International where such assignment has not been previously recorded).

 

8.3.          Conditions to the Selling
Parties’ Obligations.  The
obligations of the Selling Parties to consummate the transactions contemplated
by this Agreement shall be subject to the fulfillment at or prior to the
Closing of each of the following conditions:

 

8.3.1.       Intentionally Omitted.

 

8.3.2.       Intentionally Omitted.

 

8.3.3.       Notice of Buyers.  Methode shall have delivered to the
Shareholder written notice identifying one or more Subsidiary of Methode (or
Methode itself) as the Buyer(s) for the Purchased Assets and Purchased
Shares and for each such Buyer, identifying which of the Purchased Assets
(whether by the identity of the Seller owning such Purchased Assets or by
location of such Purchased Assets or otherwise) or Purchased Shares such Buyer
will acquire hereunder.

 

8.3.4.       Approvals.  All material authorizations, consents,
waivers or approvals or other action required in connection with the execution,
delivery and performance of this Agreement by Methode and the Buyers, and the
consummation by Methode and the Buyers of the transactions contemplated hereby
shall have been obtained.

 

8.3.5.       Ampcontrol Agreement.  A Buyer designated by Methode shall have executed
and delivered to Ampcontrol, Inc. the Ampcontrol Agreement.

 

8.3.6.       German Distribution
Agreements.  A Buyer
designated by Methode shall have executed and delivered to Hetronic Deutschland
the German Distribution Agreements.

 

8.3.7.       Consulting Agreement.  A Buyer designated by Methode shall have
executed and delivered to the Shareholder the Consulting Agreement.

 

8.3.8.       Escrow Agreement. Methode and
the Escrow Agent shall have executed and delivered to Hetronic Holding the
Escrow Agreement.

 

8.3.9.       Lease Addendum. A Buyer
designated by Methode shall have executed and delivered to Hetronic Holding the
Lease Addendum.

 

8.3.10.     Employment Agreements.  A Buyer designated by Methode shall have
entered into, or offered to enter into, the Employment Agreement with Torsten
Rempe, and such Employment Agreement shall not have been amended, cancelled,
terminated or otherwise modified by such Buyer.

 

8.3.11.     Closing Documents.  The following documents shall have been
delivered to Hetronic Holding:

 

31

 

(a)           Instruments of Assumption. An instrument
of assumption from each Buyer assuming the Assumed Liabilities assumed by such
Buyer, duly executed by the applicable Buyer.

 

(b)           Secretary’s Certificates.  A certificate of the Secretary of each Buyer
dated as of the Closing Date certifying (i) that the existence and good
standing such Buyer has not changed since the date of the certificates of legal
existence and good standing delivered to Sellers, (ii) the resolutions of
the applicable management or supervisory board for such Buyer authorizing the
execution, delivery and performance of this Agreement and/or all other
agreements, instruments, certificates and documents executed by such Person in
connection herewith, and (iii) the incumbency of the officers of such
Buyer executing and delivering this Agreement and/or all other agreements,
instruments, certificates and documents executed by such Buyer in connection
herewith.

 

(c)           Good Standing Certificates.  Certificates of legal existence and good
standing for each Buyer issued as of a recent date prior to the Closing Date by
the Secretary of State or other applicable Governmental Authority of each
jurisdiction in which such Buyer is organized.

 

8.3.12.     German Local Transfer
Agreement.  A Buyer
designated by Methode shall have executed and delivered to Hetronic Europe the
German Local Transfer Agreement.

 

8.3.13.     Intercompany Agreement
Termination Documents. Hetronic Asia shall have executed and
delivered to Hetronic Holding the Intercompany Agreement Termination Documents.

 

8.4.          Payment. The Closing
Payment shall be paid in accordance with Section 4.3 at Closing.

 

9.             TERMINATION.

 

9.1.          Termination of Agreement
Prior to Closing.  This
Agreement and the transactions contemplated hereby may be terminated at any
time prior to the Closing, as follows:

 

9.1.1.       Mutual Consent.  By mutual written agreement of Methode and
the Shareholder.

 

9.1.2.       Breach.  By the Shareholder by reason of the breach by
Methode in any material respect of any of its representations, warranties,
covenants or agreements contained in this Agreement. By Methode by reason of
the breach by any of the Selling Parties in any material respect of any of its
or their representations, warranties, covenants or agreements contained in this
Agreement. In the event of an alleged breach, the non-breaching party shall
provide written notice of such breach to the breaching party (the “Breach
Notice”), and the non-breaching party may only proceed to terminate this
Agreement in the event the non-breaching party fails to cure such breach within
fifteen (15) days of the receipt of the Breach Notice.

 

32

 

9.1.3.       Respective Conditions.  By Methode or by the Shareholder if the
conditions precedent to their respective obligations contained in Sections 8.2
or 8.3 hereof have not been met in all material respects at the Closing through
no fault of the terminating party or its Affiliates by October 1, 2008,
or such later date as may be agreed to by Methode and the Shareholder (the “Drop
Dead Date”).

 

9.1.4.       Mutual Conditions.  By Methode or by the Shareholder if any of
the conditions described in Section 8.1 shall not have been fulfilled
through no fault of the terminating party (or its Affiliates) by the Drop Dead
Date.

 

9.2.          Effect of Termination Prior
to Closing.  If this
Agreement is terminated pursuant to Section 9.1 above, all rights and
obligations of the parties hereunder shall terminate without any Liability on
the part of any party, except for any Liability of any party then in breach of
any representations, warranties, covenants or obligations hereunder.

 

10.           INDEMNIFICATION.

 

10.1.        Limited Indemnification
Obligations of Methode. 
Methode covenants and agrees with the Selling Parties that it shall
reimburse and indemnify the Selling Parties (the “Seller Indemnified Parties”)
for, and hold harmless the Seller Indemnified Parties from, any and all Claims
incurred by any of the Seller Indemnified Parties that result from:

 

(a)           any inaccuracy in or breach
of any representations or warranties made by Methode in this Agreement or the
schedules or any other written statement, list, certificate or other instrument
furnished to the Selling Parties by or on behalf of Methode pursuant to this Agreement;

 

(b)           any nonfulfillment of any
covenant or agreement of Methode under this Agreement;

 

(c)           any Claims made by a third
party alleging facts which, if true, would entitle the Seller Indemnified
Parties to indemnification pursuant to (a) or (b) above;

 

(d)           any failure of Methode to
comply with its obligations under this Section 10.1; or

 

(e)           any fees or expenses
(including reasonable attorneys’ fees) incurred by the Seller Indemnified
Parties in enforcing their rights under this Section 10.1.

 

10.2.        General Indemnification
Obligations of Methode. 
Methode covenants and agrees with the Selling Parties that it shall
reimburse and indemnify the Seller Indemnified Parties for, and hold harmless
the Seller Indemnified Parties from, any and all Claims incurred by any of the
Seller Indemnified Parties that result from:

 

(a)           any Assumed Liabilities;

 

33

 

(b)           any fees, expenses or other
payments incurred or owed by Methode to any brokers or comparable third parties
retained or employed by Methode or its Affiliates in connection with the
transactions contemplated by this Agreement;

 

(c)           any Liability arising from
any claim for personal injury, property damage, or strict liability arising out
of the sale by any Buyer of any Inventories included in the Acquired Assets
(whether constituting finished goods as of the Closing or work in process as of
the Closing and subsequently completed by the Buyers) and sold by a Buyer after
the Closing Date (the “Inventory Products Liability Claims”);

 

(d)           any fees, expenses or other
payments incurred or owed by Methode or any of the Buyers to any brokers,
finders or comparable third parties retained or employed by them or their
Affiliates in connection with the transactions contemplated by this Agreement;

 

(e)           any Claims made by a third
party alleging facts which, if true, would entitle the Seller Indemnified
Parties to indemnification pursuant to (a) through (d) above;

 

(f)            any failure of Methode to
comply with its obligations under this Section 10.2; or

 

(g)           any fees or expenses
(including reasonable attorneys’ fees) incurred by the Seller Indemnified
Parties in enforcing their rights under this Section 10.2.

 

10.3.        Limited Indemnification
Obligations of the Selling Parties.  The Selling Parties, jointly and severally,
covenant and agree with Methode that they shall reimburse and indemnify Methode
and its Affiliates (including the Buyers and Hetronic Asia) and their
respective directors, officers, employees, licensees and agents (the “Methode
Indemnified Parties”) for, and hold harmless Methode Indemnified Parties
from, any and all Claims incurred by any of Methode Indemnified Parties that
result from:

 

(a)           any inaccuracy in or breach
of any representations or warranties made by the Selling Parties in this
Agreement or the schedules or any other written statement, list, certificate or
other instrument furnished to Methode by or on behalf of the Selling Parties
pursuant to this Agreement;

 

(b)           any nonfulfillment of any
covenant or agreement of any of the Selling Parties under this Agreement;

 

(c)           any Claims made by a third
party alleging facts which, if true, would entitle the Methode Indemnified
Parties to indemnification pursuant to (a) or (b) above;

 

(d)           any failure of the Selling
Parties to comply with their obligations under this Section 10.3; or

 

(e)           any fees or expenses
(including reasonable attorneys’ fees) incurred by Methode Indemnified Parties
in enforcing its rights under this Section 10.3.

 

34

 

10.4.        General Indemnification
Obligations of the Selling Parties.  The Selling Parties, jointly and severally,
covenant and agree with Methode that they shall reimburse and indemnify the
Methode Indemnified Parties for, and hold harmless Methode Indemnified Parties
from, any and all Claims incurred by any of Methode Indemnified Parties that
result from:

 

(a)           any Taxes relating to or
resulting from the conduct of the Target Companies’ business or the Acquired
Assets on or prior to the Closing Date (including any Taxes of the Target
Companies accruing due to events prior to the Closing Date for which any
Methode Indemnified Party is held liable pursuant to Section 75 of the
German Fiscal Code (Abgabenordnung)
and including any Taxes of Hetronic Asia accruing due to events on or prior to
the Closing Date other than Taxes of Hetronic Asia reflected on the Final
Closing Statement);

 

(b)           any payments or salaries,
wages, bonuses, vacation, amounts payable under Employee Plans or otherwise due
to employees or agents of any Target Company, to the extent due or payable on
or prior to the Closing Date (or any amounts due to employees or agents of any
Selling Party who are not transferred to Buyer, whether or not due or payable
on or prior to the Closing Date), other than amounts payable to employees or
agents of Hetronic Asia and reflected on the Final Closing Statement;

 

(c)           any Remedial Action required
by Environmental Law or other Environmental Claim to the extent resulting from
the conduct of the Target Companies’ business or the Acquired Assets on or
prior to the Closing Date;

 

(d)           any litigation or legal
compliance matters to the extent relating or due to the conduct of any Target
Company’s business on or prior to the Closing Date, including any claims described
in Schedule 5.15 and/or Schedule 5.20 hereto, other
than any Assumed Warranty Claims and Inventory Products Liability Claims;

 

(e)           any product liability or
strict liability, arising from occurrences on or prior to the Closing Date
(whether or not such claim is then asserted), other than any Assumed Warranty
Claims and Inventory Products Liability Claims;

 

(f)            Liabilities of Hetronic
Asia, except for (i) Liabilities of Hetronic Asia that are reflected on
the Final Closing Statement, (ii) Assumed Warranty Claims relating to
Hetronic Asia or the business of Hetronic Asia, and (iii) Inventory
Products Liability Claims relating to Hetronic Asia or the business of Hetronic
Asia;

 

(g)           any fees, expenses or other
payments incurred or owed by the Selling Parties to any brokers, finders or
comparable third parties retained or employed by them or their Affiliates in
connection with the transactions contemplated by this Agreement;

 

(h)           any Claims asserted by any
shareholder of any Target Company or Selling Party (including the Hetronic Asia
Shareholders) for any portion of the Purchase Price;

 

(i)            any and all other Excluded
Liabilities of the Sellers, except for Liabilities of the Sellers to Methode
Indemnified Parties arising under Section 10.3 of this Agreement;

 

35

 

(j)            any Claims made by a third
party alleging facts which, if true, would entitle the Methode Indemnified
Parties to indemnification pursuant to (a) through (i) above;

 

(k)           any failure of the Selling Parties
to comply with their obligations under this Section 10.4; or

 

(l)            any fees or expenses
(including reasonable attorneys’ fees) incurred by Methode Indemnified Parties
in enforcing its rights under this Section 10.4.

 

10.5.        Nature and Survival of Representations
and Warranties.  All
statements made by or on behalf of a Selling Party herein or in the schedules,
shall be deemed representations and warranties of the Selling Parties,
regardless of any investigation made by or on behalf of Methode.  The representations and warranties contained
in this Agreement and the schedules shall survive the Closing.  Neither the period of survival nor the
Liability of the Selling Parties with respect to the Selling Parties’
representations and warranties shall be reduced by any investigation made at
any time by or on behalf of Methode.  The
representations and warranties made by the Selling Parties and by Methode under
this Agreement shall expire (in the absence of a showing of willful and knowing
misrepresentation or breach) twenty four (24)  months
after the Closing Date, except that the representations and warranties made in
or pursuant to Section 5.2 (Enforceability and Authority), Section 5.4.2
(Capitalization and Ownership of Hetronic Asia), Section 5.10 (Title to Assets),
Section 5.23 (Environmental Matters) and Section 6.2 (Enforceability
and Authority), Section 5.9 (Tax Matters), Section 5.18 (Employee
Benefits), Section 5.20 (Compliance) and Section 5.24 (Product
Liability and Warranty Matters) shall survive until ninety (90) days after the
expiration of the applicable statute of limitations.  If written notice of a Claim has been given
to the party against whom indemnification is sought prior to the expiration of
the applicable representation and warranty, then the relevant representation
and warranty shall survive as to such claim, until such claim has been finally
resolved.

 

10.6.        Limitations on
Indemnification Obligations.

 

10.6.1.     Threshold.  Notwithstanding any other provision in this
Agreement to the contrary, no indemnification for Claims may be sought by a
party pursuant to Section 10.1 (Limited Indemnification Obligations of
Methode) or Section 10.3 (Limited Indemnification Obligations of the
Selling Parties) of this Agreement until the aggregate amount of all such
Claims of the Methode Indemnified Parties, on one hand, or the Seller
Indemnified Parties on the other hand, exceeds Three Hundred Thousand United States Dollars ($300,000) in the
aggregate (the “Aggregate Threshold Amount”), at which time the party
asserting such Claim shall be entitled to assert such Claims for any amount in
excess of the Aggregate Threshold Amount; provided that the parties
agree that no Claim shall be asserted pursuant to Section 10.1 (Limited
Indemnification Obligations of Methode) or Section 10.3 (Limited
Indemnification Obligations of the Selling Parties) of this Agreement unless
such Claim exceeds Ten Thousand Dollars ($10,000) (the “Individual Threshold
Amount”); and provided further that the limitations set forth in this Section 10.6.1
shall not apply to (i) Claims relating to indemnification based upon a
breach of the representations and warranties set forth in Section 5.4.2
(Capitalization and Ownership of Hetronic Asia) or Section 5.10 (Title to
Assets), (ii) Claims for payment of the 

 

36

 

Purchase Price, and (iii) Claims
relating to intentional breaches of the covenants set forth in Section 11.
For purposes of determining whether any materiality qualifier set forth in any
representation or warranty or covenant is applicable, a Claim that exceeds the
Individual Threshold Amount shall be considered material and a Claim that does
not exceed the Individual Threshold Amount shall not be considered material.
For purposes of the limitations set forth in this Section 10.6.1, groups
of related Claims arising from the same circumstances shall be treated as a
single Claim.

 

10.6.2.     General Limitation on Amount.  The aggregate liability of Selling Parties to
all Methode Indemnified Parties, on one hand, and the aggregate liability of
Methode to all Seller Indemnified Parties, on the other hand, for any and all
Claims shall be limited to the sum of Ten Million United States Dollars
($10,000,000) (the “Liability Cap”); provided, however that the Liability Cap
shall not be applicable to (a) Claims for indemnification pursuant to Section 10.2
(the General Indemnification Obligations of Methode) or Section 10.4 (the
General Indemnification Obligations for the Selling Parties), or (b) Claims
for payment of the Purchase Price.

 

10.7.        Method of Asserting Claims.  The party seeking indemnification (the “Indemnitee”)
will give prompt written notice to the other party or parties (the “Indemnitor”)
of any Claim which it discovers or of which it receives notice after the
Closing and which might give rise to a claim by it for indemnification against
Indemnitor under this Section 10, stating the nature, basis and (to the
extent known) amount thereof; provided that failure to give prompt notice shall
not jeopardize the right of any Indemnitee to indemnification unless such
failure shall have materially prejudiced the ability of the Indemnitor to
defend such Claim or to recover any payment under its applicable insurance
coverage.

 

In case of any Claim or suit
by a third party or by any Governmental Authority, or any legal, administrative
or arbitration proceeding (a “Third Party Claim”) with respect to which
Indemnitor may have liability under the indemnity agreement contained in this Section 10,
Indemnitor shall be entitled to participate in such Third Party Claim and, to
the extent desired by it, to assume the defense of such Third Party Claim, and
after notice from Indemnitor to Indemnitee of the election so to assume the
defense of such Third Party Claim, Indemnitor will not be liable to Indemnitee
for any legal or other expenses subsequently incurred by Indemnitee in
connection with the defense of such Third Party Claim, other than reasonable
costs of investigation, unless Indemnitor does not actually assume the defense
of such Third Party Claim following notice of such election, or unless separate
representation is necessary to avoid a conflict of interest, in which case such
representation shall be at the expense of the Indemnitor.  Indemnitee and Indemnitor will render to each
other such assistance as may reasonably be required of each other in order to
insure proper and adequate defense of any such Third Party Claim.  If the Indemnitor actually assumes the
defense of the Indemnitee, the Indemnitee will not make any settlement of any
Third Party Claim which might give rise to liability of Indemnitor under the
indemnity agreements contained in this Section without the written consent
of Indemnitor, which consent shall not be unreasonably withheld, and the Indemnitor
shall not agree to make any settlement of any Third Party Claim which would not
include the unconditional release of the Indemnitee without the Indemnitee’s
written consent.

 

37

 

10.8.        Setoff; Payment of Claims.  Subject to reasonable prior written notice to
the Shareholder, Methode is hereby authorized by each Selling Party  to cause any Claims it or any other Methode Indemnified Party may have
against any of the Selling Parties and any other amount owed to it by the
Selling Parties under this Agreement or otherwise to be paid by reduction or
offset of such Claims or other amounts against any amounts payable by Methode
(or any other Methode Indemnified Party) to any of the Selling Parties,
pursuant to this Agreement, (including the Closing Payment) or in any other
fashion.  The rights contained herein
shall not be exclusive, but shall be in addition to any other rights and
remedies available to Methode.  If any
Claims by Methode or any other Methode Indemnified Party are pending against
any of the Selling Parties at such time as any of the above payments would
otherwise be made by Methode (or any other Methode Indemnified Party) to any
Selling Party, then Methode (or any other Methode Indemnified Party) may
withhold from such payments any amount that would become reasonably necessary
to satisfy such Claim until such time as such Claim has been resolved; provided
that Methode’s exercise of its right of set-off is made in good faith and upon
prior written notice to the Selling Parties. 
At such time as any amounts so withheld by Methode become payable to the
Selling Parties, Methode shall pay such amounts.

 

10.9.        Treatment of Claims.  Amounts paid to or on behalf of an Indemnitor
or Indemnitee, as indemnification hereunder shall be treated as adjustments to
the Purchase Price.  If any Governmental
Authority asserts that an indemnification payment is not an adjustment to the
Purchase Price, the Indemnitor will indemnify the Indemnitee against any Tax
imposed on the receipt of such indemnification payment pursuant to this Section 10,
including any Tax imposed on any payment pursuant to this Section 10.7.

 

10.10.      Insurance Recoveries.  The amount of any losses for which an
Indemnitee shall be entitled to indemnification under this Section 10
shall be net of the amount of any insurance recoveries actually received by or
on behalf of the Indemnitee or its Affiliates from third parties with respect
to such indemnifiable losses.  If an
Indemnitee or its Affiliates receives an insurance recovery from a third party
in respect of an indemnifiable loss under this Agreement after the full amount
of such indemnifiable loss has been paid by an Indemnitor or after the
Indemnitor has made a partial payment of such indemnifiable loss and the amount
of such insurance recovery exceeds the remaining unpaid balance of such
indemnifiable loss, then the Indemnitee shall promptly remit to the Indemnitor
the excess (if any) of (i) the sum of the amount theretofore paid by such
Indemnitor in respect of such indemnifiable loss plus the amount of the
insurance recovery received from the third party in respect thereof, less (ii) the
full amount of such indemnifiable loss. 
Nothing in this Section 10.8 shall obligate an Indemnitee to seek
to recover any amounts under its insurance policies prior to, or as a condition
to, seeking indemnification under this Section 10.

 

11.           POST-CLOSING AGREEMENTS.

 

11.1.        Employees.  The Target Companies shall permit Methode and
the Buyers to have access to and contact with their employees and provide such
cooperation and assistance as Methode may reasonably request in connection with
the Buyers’ efforts to hire or retain such employees at the Closing and to
minimize any disruption or adverse impact upon the relationship between the
Target Companies and such employees arising from the transactions contemplated 

 

38

 

by this Agreement. Methode
shall cause the Buyers to offer, on the Closing Date, employment as employees-at-will
to all employees of Sellers on terms and conditions (including seniority)
comparable to (or better than) those as enjoyed by such employees on the date
of this Agreement (except that the terms of employment of any employees
executing written employment agreements with the Buyers shall be as set forth
in such employment agreements and the terms of the consulting agreement with
the Shareholder shall be as set forth in the Consulting Agreement), and the
Sellers shall terminate the employment of such employees as of the Closing
Date. It shall be a condition precedent of employment by such Buyer that
applicants complete all the standard procedures, forms and requirements
(including drug testing, execution of the standard form of Inventions and Confidentiality
Agreement used by Methode and background checks) of Methode as a precondition
to commencing employment with such Buyer. 
Nothing in this Section 11.1, express or implied, shall confer upon
any current or former employee of any Seller or other Person or legal
representative thereof any rights or remedies, including any right to
employment, continued employment for any specified period, or compensation or
benefits of any nature or kind whatsoever under or by reason of this Agreement.

 

Notwithstanding the
foregoing, the parties acknowledge that the employees of Hetronic Europe shall,
without further action by the parties, become employees of the Buyer acquiring
the Purchased Assets of Hetronic Europe and the parties agree to promptly
deliver to each employee of Hetronic Europe a written notice of the transfer of
his or her employment to the applicable Buyer in accordance with Section 613a
German Civil Code and to take such actions as may be required under applicable
Law to notify such employees of the transactions hereunder.  Such automatic transfer of employees under
applicable Law shall not affect the agreements between Methode and the Selling
Parties hereunder with respect to the allocation of responsibility between the
parties with respect to Liabilities relating to such employees (including the
provisions of Sections 3.2 and 10.4(b)).

 

11.2.        Employee Benefit Plans.  Promptly after Closing, the Buyers shall use
Reasonable Efforts to permit all employees of the Sellers hired by the Buyers
pursuant to Section 11.1 (the “Hired Employees”) holding accounts
established under the Savings Incentive Match Plan for Employees of Small
Employers maintained by the Sellers (“SIMPLE IRA Plan”) to roll over
their accounts from the SIMPLE IRA Plan into Methode’s existing 401(k) plan
or retain such accounts independently.

 

11.3.        Sales after Closing.  After Closing, all inquiries regarding
products of the Buyers, whether received by the Selling Parties or Affiliates
of the Selling Parties, shall be promptly referred to the applicable Buyer.

 

11.4.        Confidentiality. The Selling
Parties hereby acknowledge that all Trade Secrets included in the Acquired
Assets shall be owned by the Buyers upon and following Closing and each Selling
Party hereby further agrees that from and after the Closing, the Selling
Parties will not directly or indirectly disclose to anyone (except as required
by law or by a governmental or regulatory body, in which event such Selling
Party shall use reasonable efforts to notify Methode in advance of such disclosure)
such Trade Secrets, or use or exploit such Trade Secrets.

 

11.5.        Names Following the Closing.  Immediately following the Closing, the
Selling Parties shall take such further actions as requested by Methode to file
and make effective the 

 

39

 

Name Change Filings and to
otherwise allow each Buyer to make full use of the name “Hetronic” in any form
or combination, and the Selling Parties shall not thereafter use such name or
other names acquired by the Buyers hereunder or names confusingly similar
thereto.

 

11.6.        Taxes
and Expenses.  All sales, stamp and other
transfer Taxes assessed by any Governmental Authority in connection with or
arising from this Agreement shall be borne by the Selling Parties and  the Selling Parties shall indemnify, defend
and hold the Buyers harmless from any such transfer Taxes.  All other costs and expenses shall be borne
by the party incurring the particular cost or expense.

 

11.7.        Post-Closing Tax
Preparation. Cooperation on Books and Records. The Selling Parties shall
duly prepare and timely file all Tax Returns (and pay all corresponding Taxes)
relating to the Selling Parties with respect to Tax periods up to the Closing
Date with the appropriate Governmental Authorities in all jurisdictions in
which such Tax Returns are required to be filed, which Tax Returns shall be
true and correct and prepared in accordance with applicable Law and will
properly reflect the Taxes of the Selling Parties for the periods covered
thereby.  In addition, upon Methode’s
reasonable request, each of the Selling Parties shall (and shall cause their
Affiliates to) cooperate and render, at its own expense, all assistance
necessary to duly prepare and make available to the Governmental Authority all
books and records for Tax purposes (including but not limited to a proper
transfer pricing documentation) relating to the Selling Parties with respect to
Tax periods up to the Closing Date if so required by any Governmental
Authority.  In connection therewith, the
Selling Parties shall provide to the Buyers (or permit the Buyers or any
Governmental Authorities to utilize) all technical systems necessary to read
such books and records kept in electronic or photo-optical form and make them
accessible to any Governmental Authorities.

 

11.8.        Instruments of Further
Assurance.  Each of the
Selling Parties agrees, upon the request of Methode or any Buyer, from time to
time after the Closing to execute and deliver, and cause their Affiliates to
execute and deliver, to Methode or any Buyer all such instruments and documents
of further assurance or otherwise as shall be reasonable under the
circumstances, and to do any and all such acts and things as may reasonably be
required to transfer and convey to the Buyers all right, title and interest to
the Purchased Assets and Purchased Shares and to otherwise carry out the
obligations of the Selling Parties hereunder.

 

11.9.        Pro-Ration of Expenses; Tax
Refunds.  All real estate and personal
property taxes, payroll taxes, worker’s compensation premium adjustments,
utility payments, lease payments, insurance premiums, and other Taxes and other
expenses and prepayments and relating to the ownership or use of the Acquired
Assets (or conduct of the business of Hetronic Asia) and attributable to
periods of time both before and after the Closing Date shall be prorated
between the Selling Parties and the Buyers, as the case may be, as soon as a
pro rata charge or credit is reasonably determinable and Selling Parties and
the Buyers shall promptly reimburse the other for such pro rated amounts
(except to the extent that such amounts are reflected in the Final Closing
Statement). Without limitation to the foregoing, notwithstanding the effective
dates set forth in the documents assigning any Contract (including leases)
included within the Acquired Assets, the parties agree that all rent and other
obligations arising under such Contracts shall be prorated as of the Closing
Date. If Methode or Hetronic Asia receives a refund with respect to Taxes of
Hetronic Asia relating to periods prior to the Closing Date or accruing due to
events on

 

40

 

or prior to or on the
Closing Date (other than Taxes of Hetronic Asia reflected on the Final Closing
Statement), Methode will pay the amount of such refund to Hetronic Holding
within thirty (30) days of receipt.  If Hetronic
Holding or any other Selling Party receives a refund with respect to Taxes of
Hetronic Asia relating to periods after to the Closing Date or accruing due to
events after the Closing Date (or with respect to Taxes of Hetronic Asia
reflected on the Final Closing Statement), Hetronic Holding will pay the amount
of such refund to Methode within thirty (30) days of receipt.

 

11.10.      Access to Records.  The Buyers shall maintain the Acquired Records, and the
Selling Parties shall maintain the Excluded Records, in each case for a period
of three (3) years from and after the Closing Date, and each party shall,
prior to permanently disposing of the records maintained by it pursuant to this
Section 11.10, give at least sixty days written notice to the other
parties of such disposal.  During such
period as a party is required to maintain records pursuant to this Section 11.10,
such party shall provide the other parties with reasonable access to such
records and the right to make copies thereof; provided that to the extent that
a party engages a third party to manage, maintain or store its records, the
party seeking access to such records shall pay any access and/or copy fees
charged by such third party.

 

11.11.      Access to Employees.  For a period of three years after the
Closing, Methode shall permit Torsten Rempe to make himself (and such former
employees of the Sellers to whom Torsten Rempe may in his discretion delegate
such activities) available to the Sellers to a reasonable extent to provide
such assistance as the Shareholder may reasonably request in winding up
the Sellers’ affairs, provided that all requests for such assistance shall
be directed to, and handled through, Torsten Rempe and further provided that
such assistance does not materially interfere with the performance of their job
responsibilities for the Buyers.  In
addition, Methode shall not prohibit Simon Grima from continuing to hold the
office of Managing Director of Hetronic Malta (as renamed) in order to execute
such documents as the Sellers may require for so long as such activities do not
materially interfere with his performance of his job responsibilities for the
Buyers, provided that the Selling Parties acknowledge that Simon Grima’s
continued activities as Managing Director of Hetronic Malta shall be at his
discretion and Methode has no obligation to require him to continue to hold
such office.  The Selling Parties acknowledge that other employees of the
Sellers hired by the Buyers may be required to resign any offices held with the
Sellers.

 

11.12.      Receivables. Buyers shall use Reasonable
Efforts to collect all Receivables included in the Acquired Assets. In the
event any of the Receivables included in the Acquired Assets remain uncollected
twelve (12) months after the Closing Date, then Buyers shall provide the
Sellers with a detailed list of such remaining uncollected Receivables included
in the Acquired Assets and Buyers shall have the right to cause the Sellers to
repurchase such uncollected Receivables identified in writing by Buyers for the
nominal value of such uncollected Receivables (without any discount for
collectability), provided that Sellers shall not be required to repurchase, in
the aggregate, uncollected Receivables with a nominal value in excess of fifty
percent of the nominal value of all remaining uncollected Receivables included
in the Acquired Assets.  Upon
repurchasing any Receivables as required under this Section 11.12, the
Sellers shall have the right to pursue all available rights and remedies to
collect such repurchased Receivables.

 

41

 

11.13.      Enforcement of Existing NDAs.  The Selling Parties agree that in the event
that any third party violates or threatens to violate the terms of any Existing
NDA after the Closing, the Selling Parties shall, to the extent requested in
writing by the Buyers, enforce the terms of such Existing NDA against such
third party and seek such equitable relief as the Buyers may reasonably
request; provided that the Buyers shall reimburse the Selling Parties for their
reasonable out-of-pocket costs and attorneys fees incurred at the Buyer’s
request.  In the event that the Selling
Parties learn of any violation of threatened violation of the terms of any
Existing NDA after the Closing, the Selling Parties will promptly provide written
notice of the same to the Buyers.

 

11.14.      Philippine Registration of Foreign
Investment.  The Selling Parties will
provide such assistance as Methode may reasonably request to assist the efforts
of the Buyers to register the prior investment by Hetronic Holding and/or the
current investment by the Buyers in Hetronic Asia’s capital stock to enable the
Buyer to request and comply with such requirements imposed by the Bangko
Sentral ng Pilipinas.

 

12.                               GENERAL
PROVISIONS.

 

12.1.        Entire Agreement.  This Agreement and the other agreements and
documents referred to herein set forth the entire understanding of the parties
with respect to the subject matter hereof. 
Any previous agreements or understandings between the parties regarding
the subject matter hereof are merged into and superseded by this Agreement.

 

12.2.        Amendment; Waiver.  This Agreement may be amended, supplemented
or interpreted at any time only by written instrument duly executed by each of
Methode and the Shareholder. Any of the terms or conditions of this Agreement
may be waived at any time by the party or parties entitled to the benefit
thereof but only by a written notice signed by the party or parties waiving
such terms or conditions.

 

12.3.        Expenses.  Except as set forth in Section 2.4 of this
Agreement, Methode and the Buyers, on one hand, and the Selling Parties, on the
other hand, shall each pay its or their own expenses, including the expenses of
its or their own legal counsel, investment bankers, brokers and accountants,
incurred in connection with the preparation, execution and delivery of this
Agreement and the other agreements and documents referred to herein and the
consummation of the transactions contemplated hereby and thereby.

 

12.4.        Notices.  All notices, requests, demands and other
communications required or permitted to be given hereunder shall be by
hand-delivery, certified or registered mail, return receipt requested;
telecopier, or air courier to the parties set forth below.  Such notices shall be deemed given:  at the time personally delivered, if
delivered by hand or courier; on the fifth (5th) business day after being
deposited in the mail, postage prepaid, if sent certified or registered mail;
and when receipt is acknowledged by facsimile equipment if telecopied and if a
copy is also promptly mailed by certified or registered mail.

 

	
  If
  to Methode:

  	
  Methode
  Electronics, Inc.

  
	
   

  	
  7401
  West Wilson Avenue

  
	
   

  	
  Chicago,
  Illinois 60706-4548

  

 

42

 

	
   

  	
  Attention:
  President and Chief Executive Officer

  
	
   

  	
  Telecopier:
  708-867-3288

  
	
   

  	
   

  
	
  Copy
  to:

  	
  Locke
  Lord Bissell & Liddell LLP

  
	
   

  	
  111
  South Wacker Drive

  
	
   

  	
  Chicago,
  Illinois 60606

  
	
   

  	
  Attention:
  James W. Ashley, Jr., Esq.

  
	
   

  	
  Telecopier:
  312-443-0336

  
	
   

  	
   

  
	
  If
  to any Selling Party:

  	
  Mr. Max
  Heckl

  
	
   

  	
  12901
  N. Frisco Road

  
	
   

  	
  Yukon,
  Oklahoma 73099

  
	
   

  	
  Telecopier:
  214-853-5109

  
	
   

  	
   

  
	
  Copy
  to:

  	
  Kochman
  Donati & Charbonnet

  
	
   

  	
  12012
  Wickchester Lane, Suite 310

  
	
   

  	
  Houston,
  Texas  77079

  
	
   

  	
  Attention:
  Philip J. Kochman

  
	
   

  	
  Telecopier:
  713-871-2495

  

 

12.5.        Assignment.  Neither this Agreement nor any of the rights
and obligations hereunder may be assigned by any party, whether or not by
operation of law, without the prior written consent of the other parties
hereto, provided that Methode may transfer or assign this Agreement to any Person
succeeding to all or substantially all of the Acquired Assets or Purchased
Shares by way of an asset sale, merger, reorganization or otherwise without the
consent of any other parties, as long as such assignment becomes effective only
after the disbursal of all funds held pursuant to the Escrow Agreement.  No assignment of this Agreement shall relieve
the assigning party of its obligations under this Agreement or permit the
assignee to assert rights broader or different than the assigning party would
have been permitted to assert. Subject to the foregoing, this Agreement shall
be binding upon and inure to the benefit of and be enforceable by the
respective heirs, legal representatives, successors and permitted assigns of
the parties hereto.

 

12.6.        Severability.  If any term, provision, covenant or
restriction in this Agreement is held by a court of competent jurisdiction or
other authority to be invalid, void or unenforceable, the remainder of the
terms, provisions, covenants and restrictions of this Agreement shall remain in
full force and effect and shall in no way be affected, impaired or invalidated
as long as the economic or legal substance of the transactions contemplated
hereby is not affected in any manner materially adverse to either party.  Upon such a determination, the parties shall
negotiate in good faith to modify this Agreement so as to effect the original
intent of the parties as closely as possible in an acceptable manner in order
that the transactions hereby be consummated as originally contemplated to the
fullest extent possible.

 

12.7.        Counterparts; Facsimiles.  This Agreement and all documents referenced
herein may be executed in any number of counterparts, each of which may be
executed by less than all of the parties hereto, each of which shall be
enforceable against the parties actually executing such counterparts, and all
of which together shall constitute one and the same instrument. Each 

 

43

 

party is hereby authorized
to rely upon and accept as an original any executed copy of this Agreement or
other document referenced herein which is sent by facsimile, telegraphic or
other electronic transmission.

 

12.8.        Construction.  Section and subsection headings
contained in this Agreement are inserted for convenience of reference only,
shall not be deemed to be a part of this Agreement for any purpose, and shall
not in any way define or affect the meaning, construction or scope of any of
the provisions hereof. The terms “hereof,” “herein” and “hereunder” and terms
of similar import are references to this Agreement as a whole and not to any
particular provision of this Agreement. 
Section, clause, schedule and exhibit references contained in this
Agreement are references to sections, clauses, schedules and exhibits in or to
this Agreement, unless otherwise specified. Common nouns and pronouns shall be
deemed to refer to the masculine, feminine, neuter, singular and plural, as the
identity of the person may in the context require.  The use of the words “include,” “including”
or variations thereof in this Agreement shall be by way of example rather than
by limitation. The parties hereto acknowledge that all parties participated
equally in the drafting and negotiation of this Agreement and were represented
by counsel of their own choosing in connection therewith.  Consequently, this Agreement shall be
construed without referencing to any rule of law, which provides that
ambiguities in a contract are to be resolved against the drafter thereof.  The official language of this Agreement is,
and shall continue for all purposes to be, the English language.

 

12.9.        Public Announcements.  No notices to third parties or other
publicity, including press releases, employee notifications, vendor
notifications and customer notifications, concerning any of the transactions
provided for herein shall be made by any party hereto unless planned and
coordinated jointly among the parties hereto, with each party approving any
press release in writing prior to release; provided that nothing herein shall
restrict or delay either party from issuing any press release or other
publicity to the extent required by Law.

 

12.10.      No Third Party Beneficiaries.  Except for the provisions of Section 10
relating to indemnified parties under this Agreement, (i) the provisions
of this Agreement are solely for the benefit of the parties hereto and are not
intended to confer upon any Person except the parties hereto any rights or
remedies hereunder, and (ii) there are no third party beneficiaries of
this Agreement and this Agreement shall not provide any third party with any
remedy or Claim or other right in excess of those existing without reference to
this Agreement.

 

12.11.      Waiver of Trial by Jury.  The parties hereby knowingly, voluntarily and
intentionally waive any right they may have to a trial by jury in respect to
any litigation arising out of, under or in connection with this Agreement, or
any course of conduct, course of dealing, statements (whether verbal or
written) or actions of any party to this Agreement.  This provision is a material inducement for
Methode and the Selling Parties entering into this Agreement.

 

12.12.      Cumulative Remedies.  All rights and remedies of the parties to
this Agreement are cumulative of each other and of every other right or remedy
such parties may otherwise have at law or in equity, and the exercise of one or
more rights or remedies shall not prejudice or impair the concurrent or
subsequent exercise of other rights or remedies.

 

44

 

12.13.      Governing Law; Jurisdiction.  This Agreement shall be governed, construed
and enforced in accordance with the internal laws of the State of Delaware,
excluding any choice of law rules which may direct the application of the
laws of another jurisdiction. The parties hereby covenant and agree that any
and all actions arising out of or related to this Agreement shall  be brought and maintained in the federal
and state courts sitting in Harris County, Texas, and each party to this Agreement
hereby irrevocably consents and submits to the exclusive jurisdiction of and
the service of process from such courts for any and all such actions.

 

12.14.      Authority of the Shareholder to Bind
the Selling Parties. Each the Selling Party acknowledges and agrees that
the Shareholder shall have sole authority on behalf of each of and all of the
Selling Parties to agree to, dispute or otherwise handle all matters relating
to this Agreement, including matters relating to the Closing Statement, the
Independent Accounting Firm, the assertion, waiver or defense of claims under Section 10,
amendment of this Agreement pursuant to Section 12.2 and otherwise, in
each case as the Shareholder deems appropriate in his sole and absolute
discretion.  Each Selling Party hereby
agrees that any determination by the Shareholder with respect to any matters
relating to this Agreement shall be conclusive and binding upon such Selling
Party.

 

12.15.      Schedules. Any disclosure in a
schedule to this Agreement with respect to a Section of this Agreement
shall be deemed to be disclosed for other Sections of this Agreement to the
extent that such disclosure sets forth facts in sufficient detail so that the
relevance of such disclosure would be reasonably apparent to a reader of such disclosure.  No reference to or disclosure of any item or
other matter in any schedule of this Agreement shall be construed as an
admission or indication that such item or other matter is material or that such
item or other matter is required to be referred to or disclosed in this
Agreement.

 

[SIGNATURES ON FOLLOWING PAGE]

 

45

 

IN WITNESS WHEREOF, this
Agreement has been duly executed by the parties to this Agreement on the day
and year first above written.

 

	
  HETRONIC
  HOLDING LLC

  	
   

  	
  HETRONIC
  INTERNATIONAL, INC.

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  
	
  By:
  

  	
  /s/
  Max Heckl

  	
   

  	
  By:
  

  	
  /s/
  Torsten Rempe

  
	
  Name:

  	
  Max
  Heckl

  	
   

  	
  Name:

  	
  Torsten
  Rempe

  
	
  Title:

  	
  President

  	
   

  	
  Title:

  	
  President

  
	
   

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  
	
  HETRONIC
  USA INC.

  	
   

  	
  HETRONIC
  WEST, INC.

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  
	
  By:
  

  	
  /s/
  Torsten Rempe

  	
   

  	
  By:
  

  	
  /s/
  Torsten Rempe

  
	
  Name:

  	
  Torsten
  Rempe

  	
   

  	
  Name:

  	
  Torsten
  Rempe

  
	
  Title:

  	
  President

  	
   

  	
  Title:

  	
  President

  
	
   

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  
	
  HETRONIC
  MALTA LIMITED

  	
   

  	
  HETRONIC
  EUROPE GMBH

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  
	
  By:
  

  	
  /s/
  Simon Grima

  	
   

  	
  By:
  

  	
  /s/
  Nicole Heckl

  
	
  Name:

  	
  Simon
  Grima

  	
   

  	
  Name:

  	
  Nicole
  Heckl

  
	
  Title:

  	
  Managing
  Director

  	
   

  	
  Title:

  	
  Managing
  Director

  
	
   

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  
	
  /s/
  Max Heckl

  	
   

  	
   

  	
   

  
	
  Max
  Heckl

  	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  
	
  METHODE
  ELECTRONICS, INC.

  	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
   

  
	
  By:

  	
  /s/
  Donald Duda

  	
   

  	
   

  	
   

  
	
  Name:

  	
  Donald
  Duda

  	
   

  	
   

  	
   

  
	
  Title:

  	
  President
  and Chief Executive Officer

  	
   

  	
   

  	
   

  

 

[Asset
and Share Purchase Agreement Signature Page]

 

 

APPENDIX OF DEFINITIONS

 

The following definitions
shall be applicable for purposes of the Agreement except as otherwise
specifically provided to the contrary in the text of the Agreement.

 

“Affiliates” of a
Person shall mean any Person controlling, controlled by or under common control
with that Person.  “Control” for this
purpose shall mean the possession, directly or indirectly, of the power to
direct or cause the direction of the management and policies of a Person,
whether through the ownership of voting securities or interests, by contract,
or otherwise.

 

“Acquired Assets”
shall mean the Purchased Assets and all of the assets and properties wherever
situated, of Hetronic Asia.

 

“Acquired Liabilities”
shall mean the Assumed Liabilities and all of the Liabilities of Hetronic Asia
as of the Closing.

 

“CERCLA” shall mean
the Comprehensive Environmental Response Compensation and Liability Act of
1980, as amended.

 

“Claim” shall mean
any action, suit, claim, proceeding, investigation, hearings, audit, charge,
complaint, demand, injunction, judgment, order, decree, ruling, loss, Tax,
Lien, Liability, assessment, fine, penalty, amount paid in settlement, damage,
cost or expense (including court costs, reasonable attorneys’ fees, expert
fees, travel expenses, court costs and other expenditures).

 

“Code” shall mean the
Internal Revenue Code of 1986, as amended.

 

“Contract” shall mean
any oral or written contract, agreement, lease, indenture, commitment or
understanding (including purchase orders, sales orders and supply contracts).

 

“Employee Plan” shall
mean any pension, retirement, savings, accident, disability, medical, dental,
health, life (including any individual life insurance policy to which any Target Company makes premium
payments, whether or not such party is the owner, beneficiary or both of such
policy), death benefit, group insurance, profit sharing, compensation, deferred
compensation, stock purchase, stock option, stock ownership, stock appreciation
rights, phantom stock, bonus, incentive, leave of absence, layoff, vacation pay
or sick day, severance, separation, dependent care, legal services, cafeteria,
or other employee benefit plan, trust, contract, agreement, practice, policy,
commitment or arrangement of any kind, whether any of the foregoing is funded,
insured or self-funded, for the benefit of a single individual or more than one
individual, written or oral, (a) to which any Target Company is a party or by which any Target Company (or any of its rights,
properties or assets) is bound, or (b) with respect to which any Target Company has made any payments,
contributions or commitments, or may otherwise have any liability (whether or
not any such party still maintains such plan, trust, arrangement, contract,
agreement, policy or commitment), including, any Welfare Plan, any Pension Plan
and any “employee benefit plan” within the meaning of Section 3(3) of
ERISA.

 

“Environment” shall
mean surface waters, groundwaters, surface water sediment, soil, subsurface
strata, ambient air and other environmental medium.

 

1

 

“Environmental Claims”
shall mean any and all actions, suits, demands, demand letters, claims, Liens,
notices of non-compliance or violation, notices of Liability or potential
Liability, investigations, proceedings, consent orders or consent agreements
relating in any way to any Environmental Law, Environmental Permit or any
Hazardous Material or arising from any alleged injury to threat of injury to
health, safety or the Environment.

 

“Environmental Law”
shall mean any Law relating to pollution or protection of the Environment,
health, safety or natural resources or to the use, handling, transportation,
treatment, storage, disposal, Release or discharge of Hazardous Materials,
including CERCLA.

 

“Environmental Permit”
shall mean any permit, approval, identification number, license, or other
authorization or application therefor required to operate any Target Company’s business under any
applicable Environmental Law.

 

“ERISA” shall mean
the Employee Retirement Income Security Act of 1974, as amended.

 

“Governmental Authority”
shall mean any United States federal, state, municipal or local or any non-U.S.
government, governmental, regulatory or administrative authority, state
enterprise, department, agency, commission, board, bureau, or instrumentality
(or political subdivision thereof) or any court, tribunal, or judicial or
arbitral body.

 

“Hazardous Materials”
shall mean any waste or other substance that is listed, defined, designated or
classified as, or otherwise determined to be, hazardous, radioactive, dangerous
or toxic or a pollutant or a contaminant or otherwise regulated under or
pursuant to any Environmental Law, including any admixture or solution thereof,
and specifically including petroleum and all derivatives thereof or synthetic
substitutes therefore, radioactive materials, asbestos or asbestos-containing
materials, and polychlorinated biphenyls.

 

“Indebtedness” of any
Person shall mean all obligations (whether interest, principal, fees, penalties
or otherwise) and Liabilities consisting of, without duplication: (a) indebtedness
for borrowed money or for the deferred purchase price of property or services
in respect of which such Person is liable, contingently or otherwise, as
obligor or otherwise (other than trade payables and other current liabilities
incurred in the Ordinary Course of Business) and any commitment by which such
Person assures a creditor against loss, including contingent reimbursement
obligations with respect to letters of credit; (b) obligations evidenced
by debt securities bonds, debentures, notes or other similar instruments; (c) obligations
under capitalized leases in respect of which such Person is liable, contingently
or otherwise, as obligor, guarantor or otherwise, or in respect of which
obligations such Person assures a creditor against loss; (d) any
unsatisfied obligation of such Person for “withdrawal liability” to a “multiemployer
plan,” as such terms are defined under ERISA; (e) obligations with respect
to letters of credit issued for such Person’s account, (f) secured by a
Lien; or (viii) arising from any guaranty for any of the foregoing,
including a guarantee in the form of an agreement to repurchase or reimburse.

 

“Intellectual Property”
shall mean (a) all trademarks, service marks, certification marks, trade
dress, logos, trade names, Internet domain names, and corporate names, together
with all 

 

2

 

translations,
adaptations, derivations, and combinations thereof and including all goodwill
associated therewith, and all applications, registrations, and renewals in
connection therewith, (b) all copyrightable works (whether or not
published or registered), all copyrights, mask works, derivative works thereof,
and all applications, registrations, and renewals in connection therewith, (c) all
Trade Secrets; (d) all patents and patent applications, and all divisions,
reissues, continuations, extensions, and continuations-in-part thereof, and all
inventor’s certificates and utility models, (e) all computer software
(including data and related documentation), (f) and all other forms of
intellectual property or proprietary rights, and (g) all copies and
tangible embodiments thereof (in whatever form or medium).

 

“Inventories” shall
mean all inventories, including all raw materials, supplies, work-in-process,
and finished goods, including any of the foregoing which have been purchased
subject to any conditional sales or title retention agreement in favor of any
other Person.

 

“IRS” shall mean the
Internal Revenue Service.

 

“Key Employees” shall
mean Simon Grima, Hans-Ullrich John and Torsten Rempe.

 

“Knowledge”  The phrase “to Sellers’ Knowledge” or similar
phrases shall mean those facts and circumstances known to the Shareholder or
any of the Key Employees, in each case after due inquiry by such persons to
those employees of the Target Companies who in the ordinary course of their
duties would be reasonably likely to have knowledge of the facts or
circumstances in question.

 

“Law(s)” shall mean
any federal, state, local or foreign statute, law, ordinance, regulation, rule,
code, order, other requirement or rule of law, now or hereafter in effect
and as amended, and any judicial or administrative interpretation thereof,
including any judicial or administrative order, consent decree or judgment.

 

“Liability” shall
mean any debt, obligation, assessment, fine, penalty, damage, cost, expense or
other liability, whether direct or indirect, whether known or unknown, whether
asserted or unasserted, whether absolute or contingent, whether accrued or
unaccrued, whether matured or unmatured, whether liquidated or unliquidated,
and whether due or to become due.

 

“Lien” shall mean any
mortgage, lien, pledge, charge, security interest, encumbrance or other third
party interest or claim of any nature whatsoever, including to the foregoing in
the case of real property, any rights-of-way, building use restrictions,
exceptions, variances, reservations, or limitations of any nature.

 

“Material Adverse Effect”
shall mean a material adverse effect upon or change in (i) the business,
affairs, properties, assets, Liabilities, financial condition or results of
operation of any Target Company,
(ii) the continued conduct of the business of any Target Company, as presently conducted, or (iii) the
ability of the Parties to consummate the transaction contemplated by this
Agreement.

 

“Ordinary Course of
Business” shall mean the ordinary course of business consistent with past
custom and practice (including with respect to quantity and frequency).

 

3

 

“Organizational
Documentation” of a Person shall mean the certificate of incorporation,
certificate of formation, articles of incorporation, by-laws, operating
agreement or other organic document of such Person.

 

“Pension Plan” shall
have the meaning defined in Section 3(2) of ERISA.

 

“Person” shall mean
an individual, a partnership, a corporation, a limited liability company, an
association, a joint stock company, a trust, a joint venture, an unincorporated
organization, a Governmental Authority (or department, agency or political
subdivision thereof) or any other person or entity.

 

“Reasonable Efforts”
shall mean the good faith effort that a Person ordinarily would use, apply or
exercise to protect his own rights and business, provided that when used in
connection with the obtaining of a consent, approval or other act of an
unaffiliated third party or Governmental Authority, “reasonable efforts” shall
not require the commencement of litigation against or acquisition of control of
such third party or the assets or obligations requiring such consent, the
acceleration of payment of any indebtedness or the payment of money.

 

“Receivables” shall
mean all trade receivables, note receivables and other accounts receivable.

 

“Release” shall mean
actual disposing, discharging, injecting, spilling, leaking, leaching, dumping,
emitting, escaping, emptying, seeping, placing, and the like into or upon any
land or water or air or otherwise into the Environment.

 

“Remedial Action”
shall mean any investigation, assessment, monitoring, treatment, response,
excavation, removal, remediation, or cleanup of Hazardous Materials in the
Environment.

 

“Subsidiary” shall
mean any Person with respect to which a specified Person (or Subsidiary
thereof) owns a majority of the common stock or has the power to vote or direct
the voting of sufficient securities to elect a majority of the directors (or individuals
exercising similar functions).

 

“Taxes” shall mean
all federal, state, local and foreign income, excise, property, sales, use,
payroll, intangibles, franchise, gross receipts, license, employment,
severance, stamp, occupation, premium, windfall profits, environmental, customs
duties, capital stock, profits, withholding, social security, unemployment,
disability, real property, personal property, transfer, registration, value
added, alternative or add-on minimum and other taxes, fees, assessments or
charge of whatever nature, and all penalties and interest related thereto,
whether disputed or not, including tax withholdings or amounts paid to any
Person or Liabilities for taxes as a result of being a member of a unitary,
consolidated or similar group or as a result of being a party to any tax
sharing, tax indemnity, tax allocation or similar agreement or arrangement.

 

“Tax Return” shall
mean any return, declaration, report, claim for refund, or information return
or statement relating to Taxes, including any schedule or attachment thereto,
and including any amendment thereof.

 

4

 

“Target Company
Intellectual Property” shall mean any and all Intellectual Property owned
by, licensed by or used by any Target Company or Target Companies, including
all Intellectual Property incorporated into the radio remote control products
developed, manufactured, marketed or sold by the Target Companies, the
corporate and trade name “Hetronic,” derivatives and all telephone numbers of
the Target Companies, including those rights described in Schedule 5.19
hereto.

 

“Trade Secrets” shall
mean all trade secrets and confidential business information including all
inventions, compositions, manufacturing and production processes and
techniques, business methods, processes and techniques (in each case whether or
not patentable), discoveries, developments, ideas, concepts, research and
development, databases, shoprights, designs, formulae, methods, processes,
designs, drawings, blueprints, engineering computer information,
specifications, and items of proprietary know-how, information or data;
prospect lists, customer lists, supplier lists, projections, analyses and
market studies, pricing and cost information, and business and marketing plans
and proposals; and all other proprietary rights; provided that “Trade Secrets”
do not include non-proprietary information, know-how or processes otherwise
available to the industry or the public.

 

“Welfare Plan” shall
have the meaning defined in Section 3(1) of ERISA.

 

5

 

ASSET AND SHARE PURCHASE AGREEMENT

 

 

by and among

 

 

METHODE ELECTRONICS, INC.;

 

 

HETRONIC HOLDING LLC

 

and certain of its affiliates

 

and

 

Max Heckl

 

 

Dated as of September 30, 2008

 

 

TABLE OF CONTENTS

 

	
  1.

  	
  PURCHASE AND SALE OF ASSETS AND SHARES

  	
  2

  
	
   

  	
  1.1.

  	
  Agreement to Purchase and Sell Assets

  	
  2

  
	
   

  	
  1.2.

  	
  Agreement to Purchase and Sell Shares

  	
  3

  
	
   

  	
  1.3.

  	
  Excluded Assets

  	
  4

  
	
   

  	
  1.4.

  	
  Documentation

  	
  5

  
	
  2.

  	
  CONSIDERATION

  	
  5

  
	
   

  	
  2.1.

  	
  Purchase Price

  	
  5

  
	
   

  	
  2.2.

  	
  Reconciliation of Net Book Value

  	
  5

  
	
   

  	
  2.3.

  	
  Settlement

  	
  6

  
	
   

  	
  2.4.

  	
  Independent Accounting Firm

  	
  7

  
	
   

  	
  2.5.

  	
  Allocation of Purchase Price

  	
  7

  
	
  3.

  	
  ASSUMED LIABILITIES AND EXCLUDED LIABILITIES

  	
  8

  
	
   

  	
  3.1.

  	
  Assumed Liabilities

  	
  8

  
	
   

  	
  3.2.

  	
  Excluded Liabilities

  	
  8

  
	
  4.

  	
  CLOSING

  	
  8

  
	
   

  	
  4.1.

  	
  Closing

  	
  8

  
	
   

  	
  4.2.

  	
  Closing Deliverables

  	
  9

  
	
   

  	
  4.3.

  	
  Closing Payment

  	
  9

  
	
   

  	
  4.4.

  	
  Location and Effective Time of Closing

  	
  9

  
	
  5.

  	
  REPRESENTATIONS AND WARRANTIES OF SELLING PARTIES

  	
  10

  
	
   

  	
  5.1.

  	
  Organization and Good Standing

  	
  10

  
	
   

  	
  5.2.

  	
  Enforceability and Authorization

  	
  10

  
	
   

  	
  5.3.

  	
  No Conflict; Consents

  	
  10

  
	
   

  	
  5.4.

  	
  Capitalization and Ownership; Corporate Matters

  	
  11

  
	
   

  	
  5.5.

  	
  Financial Statements

  	
  12

  
	
   

  	
  5.6.

  	
  Books and Records

  	
  12

  
	
   

  	
  5.7.

  	
  No Undisclosed Liabilities

  	
  12

  
	
   

  	
  5.8.

  	
  Absence of Certain Changes

  	
  13

  
	
   

  	
  5.9.

  	
  Tax Matters

  	
  15

  
	
   

  	
  5.10.

  	
  Title to Assets

  	
  16

  
	
   

  	
  5.11.

  	
  Real Estate and Leases

  	
  16

  
	
   

  	
  5.12.

  	
  Material Contracts

  	
  17

  
	
   

  	
  5.13.

  	
  Receivables

  	
  18

  
	
   

  	
  5.14.

  	
  Inventories

  	
  19

  
	
   

  	
  5.15.

  	
  Litigation

  	
  19

  
	
   

  	
  5.16.

  	
  Insurance

  	
  19

  
	
   

  	
  5.17.

  	
  Employment and Labor Matters

  	
  19

  
	
   

  	
  5.18.

  	
  Employee Benefits

  	
  20

  
	
   

  	
  5.19.

  	
  Intellectual Property

  	
  21

  
	
   

  	
  5.20.

  	
  Legal Compliance

  	
  23

  
	
   

  	
  5.21.

  	
  Approvals

  	
  23

  
	
   

  	
  5.22.

  	
  Transactions with Affiliates

  	
  23

  
	
   

  	
  5.23.

  	
  Environmental Matters

  	
  24

  
	
   

  	
  5.24.

  	
  Product Liability and Warranty Matters

  	
  25

  

 

i

 

	
   

  	
  5.25.

  	
  Principal Customers and Suppliers

  	
  26

  
	
   

  	
  5.26.

  	
  Solvency

  	
  26

  
	
   

  	
  5.27.

  	
  Material Adverse Affect

  	
  26

  
	
   

  	
  5.28.

  	
  Disclosure

  	
  26

  
	
  6.

  	
  REPRESENTATIONS AND WARRANTIES OF METHODE

  	
  26

  
	
   

  	
  6.1.

  	
  Organization

  	
  27

  
	
   

  	
  6.2.

  	
  Enforceability and Authorization

  	
  27

  
	
   

  	
  6.3.

  	
  No Conflict; Methode Consents

  	
  27

  
	
  7.

  	
  INTENTIONALLY OMITTED

  	
  28

  
	
  8.

  	
  CONDITIONS TO CLOSING

  	
  28

  
	
   

  	
  8.1.

  	
  Mutual Conditions

  	
  28

  
	
   

  	
  8.2.

  	
  Conditions to Methode’s Obligations

  	
  28

  
	
   

  	
  8.3.

  	
  Conditions to the Selling Parties’ Obligations

  	
  31

  
	
   

  	
  8.4.

  	
  Payment

  	
  32

  
	
  9.

  	
  TERMINATION

  	
  32

  
	
   

  	
  9.1.

  	
  Termination of Agreement Prior to Closing

  	
  32

  
	
   

  	
  9.2.

  	
  Effect of Termination Prior to Closing

  	
  33

  
	
  10.

  	
  INDEMNIFICATION

  	
  33

  
	
   

  	
  10.1.

  	
  Limited Indemnification Obligations of Methode

  	
  33

  
	
   

  	
  10.2.

  	
  General Indemnification Obligations of Methode

  	
  33

  
	
   

  	
  10.3.

  	
  Limited Indemnification Obligations of the Selling Parties

  	
  34

  
	
   

  	
  10.4.

  	
  General Indemnification Obligations of the Selling Parties

  	
  35

  
	
   

  	
  10.5.

  	
  Nature and Survival of Representations and Warranties

  	
  36

  
	
   

  	
  10.6.

  	
  Limitations on Indemnification Obligations

  	
  36

  
	
   

  	
  10.7.

  	
  Method of Asserting Claims

  	
  37

  
	
   

  	
  10.8.

  	
  Setoff; Payment of Claims

  	
  38

  
	
   

  	
  10.9.

  	
  Treatment of Claims

  	
  38

  
	
   

  	
  10.10.

  	
  Insurance Recoveries

  	
  38

  
	
  11.

  	
  POST-CLOSING AGREEMENTS

  	
  38

  
	
   

  	
  11.1.

  	
  Employees

  	
  38

  
	
   

  	
  11.2.

  	
  Employee Benefit Plans

  	
  39

  
	
   

  	
  11.3.

  	
  Sales after Closing

  	
  39

  
	
   

  	
  11.4.

  	
  Confidentiality

  	
  39

  
	
   

  	
  11.5.

  	
  Names Following the Closing

  	
  39

  
	
   

  	
  11.6.

  	
  Taxes and Expenses

  	
  40

  
	
   

  	
  11.7.

  	
  Post-Closing Tax Preparation

  	
  40

  
	
   

  	
  11.8.

  	
  Instruments of Further Assurance

  	
  40

  
	
   

  	
  11.9.

  	
  Pro-Ration of Expenses; Tax Refunds

  	
  40

  
	
   

  	
  11.10.

  	
  Access to Records

  	
  41

  
	
   

  	
  11.11.

  	
  Access to Employees

  	
  41

  
	
   

  	
  11.12.

  	
  Receivables

  	
  41

  
	
   

  	
  11.13.

  	
  Enforcement of Existing NDAs

  	
  42

  
	
   

  	
  11.14.

  	
  Philippine Registration of Foreign Investment

  	
  42

  
	
  12.

  	
  GENERAL PROVISIONS

  	
  42

  
	
   

  	
  12.1.

  	
  Entire Agreement

  	
  42

  
	
   

  	
  12.2.

  	
  Amendment; Waiver

  	
  42

  

 

ii

 

	
   

  	
  12.3.

  	
  Expenses

  	
  42

  
	
   

  	
  12.4.

  	
  Notices

  	
  42

  
	
   

  	
  12.5.

  	
  Assignment

  	
  43

  
	
   

  	
  12.6.

  	
  Severability

  	
  43

  
	
   

  	
  12.7.

  	
  Counterparts; Facsimiles

  	
  43

  
	
   

  	
  12.8.

  	
  Construction

  	
  44

  
	
   

  	
  12.9.

  	
  Public Announcements

  	
  44

  
	
   

  	
  12.10.

  	
  No Third Party Beneficiaries

  	
  44

  
	
   

  	
  12.11.

  	
  Waiver of Trial by Jury

  	
  44

  
	
   

  	
  12.12.

  	
  Cumulative Remedies

  	
  44

  
	
   

  	
  12.13.

  	
  Governing Law; Jurisdiction

  	
  45

  
	
   

  	
  12.14.

  	
  Authority of the Shareholder to Bind the Selling Parties

  	
  45

  
	
   

  	
  12.15.

  	
  Schedules

  	
  45

  

 

EXHIBITS

 

	
  Exhibit A

  	
   

  	
  Form of
  Adjusted Net Book Value Calculation

  
	
  Exhibit B

  	
   

  	
  Form of
  Employment Agreement

  
	
  Exhibit C

  	
   

  	
  Form of
  Ampcontrol  Agreement

  
	
  Exhibit D

  	
   

  	
  Forms
  of German Distribution Agreements

  
	
  Exhibit E

  	
   

  	
  Form of
  Consulting Agreement

  
	
  Exhibit F

  	
   

  	
  Form of
  Noncompetition and Confidentiality Agreement

  
	
  Exhibit G

  	
   

  	
  Forms
  of Opinion of Counsel to Hetronic Asia

  
	
  Exhibit H

  	
   

  	
  Form of
  Escrow Agreement

  
	
  Exhibit I

  	
   

  	
  Form of
  Lease Addendum

  
	
  Exhibit J

  	
   

  	
  Intentionally
  Omitted

  
	
  Exhibit K

  	
   

  	
  Form of
  German Local Transfer Agreement

  
	
  Exhibit L

  	
   

  	
  Form of
  Hetronic Deutschland Intercompany Assignments

  
	
   

  	
   

  	
   

  
	
  SCHEDULES

  
	
   

  	
   

  	
   

  
	
  Schedule 1.1.1

  	
   

  	
  Machinery
  and Equipment

  
	
  Schedule 1.1.4

  	
   

  	
  Assigned
  Contracts

  
	
  Schedule 1.3

  	
   

  	
  Excluded
  Contracts and Assets

  
	
  Schedule 2.5

  	
   

  	
  Allocation
  of Purchase Price

  
	
  Schedule 5.1

  	
   

  	
  Organization
  and Good Standing

  
	
  Schedule 5.3

  	
   

  	
  No
  Conflict; Consents

  
	
  Schedule 5.4.1

  	
   

  	
  Ownership
  of Sellers

  
	
  Schedule 5.4.2

  	
   

  	
  Capitalization
  and Ownership of Hetronic Asia

  
	
  Schedule 5.4.3

  	
   

  	
  Hetronic
  Asia Company Matters

  
	
  Schedule 5.5

  	
   

  	
  Financial
  Statements

  
	
  Schedule 5.7

  	
   

  	
  No
  Undisclosed Liabilities

  
	
  Schedule 5.8

  	
   

  	
  Absence
  of Certain Changes

  

 

iii

 

	
  Schedule 5.9

  	
   

  	
  Tax
  Matters

  
	
  Schedule 5.10

  	
   

  	
  Title
  to Assets

  
	
  Schedule 5.11

  	
   

  	
  Real
  Estate and Leases

  
	
  Schedule 5.12

  	
   

  	
  Material
  Contracts

  
	
  Schedule 5.13

  	
   

  	
  Receivables

  
	
  Schedule 5.15

  	
   

  	
  Litigation

  
	
  Schedule 5.16

  	
   

  	
  Insurance

  
	
  Schedule 5.17

  	
   

  	
  Employment
  and Labor Matters

  
	
  Schedule 5.18

  	
   

  	
  Employee
  Benefits

  
	
  Schedule 5.19

  	
   

  	
  Intellectual
  Property

  
	
  Schedule 5.20

  	
   

  	
  Legal
  Compliance

  
	
  Schedule 5.21

  	
   

  	
  Approvals

  
	
  Schedule 5.22

  	
   

  	
  Transactions
  with Affiliates

  
	
  Schedule 5.23

  	
   

  	
  Environmental
  Matters

  
	
  Schedule 5.24

  	
   

  	
  Product
  Liability and Warranty Matters

  
	
  Schedule 5.25

  	
   

  	
  Principal
  Customers and Suppliers

  
	
  Schedule 6.1

  	
   

  	
  Organization
  and Good Standing

  
	
  Schedule 6.3

  	
   

  	
  No
  Conflict; Consents

  
	
  Schedule 8.2.3

  	
   

  	
  Required
  Consents and Approvals

  

 

iv

 

EXHIBIT A

FORM OF ADJUSTED NET BOOK VALUE CALCULATION

 

See
attached.

 

 

EXHIBIT B

FORM OF EMPLOYMENT AGREEMENT

 

See
attached.

 

 

EXHIBIT C

FORM OF AMPCONTROL AGREEMENT

 

See
attached.

 

 

EXHIBIT D

FORMS OF GERMAN DISTRIBUTION AGREEMENTS

 

See
attached.

 

 

EXHIBIT E

FORM OF CONSULTING AGREEMENT

 

See
attached.

 

 

EXHIBIT F

FORM OF NONCOMPETITION AND CONFIDENTIALITY AGREEMENT

 

See
attached.

 

 

EXHIBIT G

FORM OF OPINION OF COUNSEL TO HETRONIC ASIA

 

See
attached.

 

 

EXHIBIT H

FORMS OF ESCROW AGREEMENTS

 

See
attached.

 

 

EXHIBIT I

FORM OF LEASE ADDENDUM

 

See
attached.

 

 

EXHIBIT J

 

Intentionally
Omitted

 

 

EXHIBIT K

FORM OF GERMAN LOCAL TRANSFER AGREEMENT

 

See
attached.

 

 

EXHIBIT L

FORM OF HETRONIC DEUTSCHLAND INTERCOMPANY ASSIGNMENTS

 

See
attached.

 

 

SCHEDULES

 

See
attached.Exhibit 10.01

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Execution Version

 

ENGINEERING,
PROCUREMENT AND CONSTRUCTION

AGREEMENT

BETWEEN

SOUTH CAROLINA ELECTRIC & GAS COMPANY, FOR ITSELF AND 

AS AGENT FOR THE SOUTH CAROLINA PUBLIC SERVICE 

AUTHORITY, AS OWNER 

AND

A CONSORTIUM CONSISTING OF WESTINGHOUSE ELECTRIC 

COMPANY LLC AND STONE & WEBSTER, INC., AS CONTRACTOR

FOR 

AP1000 NUCLEAR POWER PLANTS

 

DATED
AS OF MAY 23, 2008

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

TABLE OF
CONTENTS

 

	
   

  	
   

  	
   

  	
  Page

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 1– DEFINITIONS

  	
  2

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 2– INTERPRETATION

  	
  16

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 3– SCOPE OF WORK

  	
  17

  
	
   

  	
   

  	
   

  	
   

  
	
  3.1

  	
   

  	
  General

  	
  17

  
	
   

  	
   

  	
   

  	
   

  
	
  3.2

  	
   

  	
  Phases of the Work

  	
  17

  
	
   

  	
   

  	
   

  	
   

  
	
  3.3

  	
   

  	
  Project Schedule

  	
  18

  
	
   

  	
   

  	
   

  	
   

  
	
  3.4

  	
   

  	
  Not Used

  	
  18

  
	
   

  	
   

  	
   

  	
   

  
	
  3.5

  	
   

  	
  Contractor Responsibilities

  	
  19

  
	
   

  	
   

  	
   

  	
   

  
	
  3.6

  	
   

  	
  Owner’s Responsibilities

  	
  21

  
	
   

  	
   

  	
   

  	
   

  
	
  3.7

  	
   

  	
  Subcontractors

  	
  23

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 4– FACILITY LICENSES, PERMITS AND APPROVALS

  	
  27

  
	
   

  	
   

  	
   

  	
   

  
	
  4.1

  	
   

  	
  Owner Permits

  	
  27

  
	
   

  	
   

  	
   

  	
   

  
	
  4.2

  	
   

  	
  Contractor Permits

  	
  28

  
	
   

  	
   

  	
   

  	
   

  
	
  4.3

  	
   

  	
  ITAACs

  	
  28

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 5– QUALITY ASSURANCE

  	
  28

  
	
   

  	
   

  	
   

  	
   

  
	
  5.1

  	
   

  	
  Quality Assurance

  	
  28

  
	
   

  	
   

  	
   

  	
   

  
	
  5.2

  	
   

  	
  Reporting of Defects, Noncompliance, Failures and Breakdowns of QA
  Programs

  	
  29

  
	
   

  	
   

  	
   

  	
   

  
	
  5.3

  	
   

  	
  Quality Control and Inspection Activities

  	
  30

  
	
   

  	
   

  	
   

  	
   

  
	
  5.4

  	
   

  	
  Access and Auditing at Contractor Facilities

  	
  30

  
	
   

  	
   

  	
   

  	
   

  
	
  5.5

  	
   

  	
  Access and Audits at Subcontractors’ Facilities

  	
  30

  
	
   

  	
   

  	
   

  	
   

  
	
  5.6

  	
   

  	
  Witness and Hold Points

  	
  31

  
	
   

  	
   

  	
   

  	
   

  
	
  5.7

  	
   

  	
  Owner’s Right to Inspect and Stop Work

  	
  32

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 6– CONTRACT PRICE

  	
  32

  
	
   

  	
   

  	
   

  	
   

  
	
  6.1

  	
   

  	
  Components of the Contract Price

  	
  32

  
	
   

  	
   

  	
   

  	
   

  
	
  6.2

  	
   

  	
  [**]

  	
  32

  
	
   

  	
   

  	
   

  	
   

  
	
  6.3

  	
   

  	
  Future Fuel Agreement and Services Agreement

  	
  33

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 7– PRICE ADJUSTMENT PROVISIONS

  	
  34

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 8– PAYMENTS

  	
  34

  
	
   

  	
   

  
	
  8.1

  	
   

  	
  Target Price and Time and Materials Payments

  	
  34

  

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

-i-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

TABLE
OF CONTENTS

 

(continued)

 

	
   

  	
   

  	
   

  	
  Page

  
	
   

  	
   

  	
   

  	
   

  
	
  8.2

  	
   

  	
  Milestone Payments

  	
  35

  
	
   

  	
   

  	
   

  	
   

  
	
  8.3

  	
   

  	
  Final Payment

  	
  35

  
	
   

  	
   

  	
   

  	
   

  
	
  8.4

  	
   

  	
  Supporting Documentation; Payment Disputes

  	
  36

  
	
   

  	
   

  	
   

  	
   

  
	
  8.5

  	
   

  	
  No Acceptance by Payment

  	
  37

  
	
   

  	
   

  	
   

  	
   

  
	
  8.6

  	
   

  	
  Security for Payment and Performance

  	
  37

  
	
   

  	
   

  	
   

  	
   

  
	
  8.7

  	
   

  	
  Separate Payments for Consortium Members

  	
  38

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 9– CHANGES IN THE WORK

  	
  38

  
	
   

  	
   

  	
   

  	
   

  
	
  9.1

  	
   

  	
  Entitlement to Change Order

  	
  38

  
	
   

  	
   

  	
   

  	
   

  
	
  9.2

  	
   

  	
  Owner-Directed Changes

  	
  39

  
	
   

  	
   

  	
   

  	
   

  
	
  9.3

  	
   

  	
  Effect of Changes

  	
  39

  
	
   

  	
   

  	
   

  	
   

  
	
  9.4

  	
   

  	
  Change Orders

  	
  40

  
	
   

  	
   

  	
   

  	
   

  
	
  9.5

  	
   

  	
  Disputes over Changes

  	
  41

  
	
   

  	
   

  	
   

  	
   

  
	
  9.6

  	
   

  	
  Changes for Contractor’s Convenience

  	
  41

  
	
   

  	
   

  	
   

  	
   

  
	
  9.7

  	
   

  	
  Optional Services and Equipment

  	
  42

  
	
   

  	
   

  	
   

  	
   

  
	
  9.8

  	
   

  	
  Changes in Import Fees and Duties

  	
  42

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 10– UNCONTROLLABLE CIRCUMSTANCES

  	
  42

  
	
   

  	
   

  	
   

  	
   

  
	
  10.1

  	
   

  	
  Performance Excused

  	
  42

  
	
   

  	
   

  	
   

  	
   

  
	
  10.2

  	
   

  	
  Notice

  	
  42

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 11– TESTING

  	
  43

  
	
   

  	
   

  	
   

  	
   

  
	
  11.1

  	
   

  	
  Scope and Objective of Testing

  	
  43

  
	
   

  	
   

  	
   

  	
   

  
	
  11.2

  	
   

  	
  Construction and Installation Tests

  	
  43

  
	
   

  	
   

  	
   

  	
   

  
	
  11.3

  	
   

  	
  Preoperational System Tests

  	
  44

  
	
   

  	
   

  	
   

  	
   

  
	
  11.4

  	
   

  	
  Startup Tests Objectives and Protocol

  	
  45

  
	
   

  	
   

  	
   

  	
   

  
	
  11.5

  	
   

  	
  Performance Tests

  	
  47

  
	
   

  	
   

  	
   

  	
   

  
	
  11.6

  	
   

  	
  Net Unit Electrical Output Guarantee

  	
  49

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 12– STAGES OF COMPLETION

  	
  51

  
	
   

  	
   

  	
   

  	
   

  
	
  12.1

  	
   

  	
  Turnover

  	
  51

  
	
   

  	
   

  	
   

  	
   

  
	
  12.2

  	
   

  	
  Preoperational Test Completion

  	
  52

  
	
   

  	
   

  	
   

  	
   

  
	
  12.3

  	
   

  	
  Startup Test Completion

  	
  52

  
	
   

  	
   

  	
   

  	
   

  
	
  12.4

  	
   

  	
  Substantial Completion

  	
  53

  
					

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

ii

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

TABLE
OF CONTENTS

 

(continued)

 

	
   

  	
   

  	
   

  	
  Page

  
	
   

  	
   

  	
   

  	
   

  
	
  12.5

  	
   

  	
  Punch List

  	
  53

  
	
   

  	
   

  	
   

  	
   

  
	
  12.6

  	
   

  	
  Final Completion

  	
  53

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 13– LIQUIDATED DAMAGES

  	
  54

  
	
   

  	
   

  	
   

  	
   

  
	
  13.1

  	
   

  	
  Delay Liquidated Damages

  	
  54

  
	
   

  	
   

  	
   

  	
   

  
	
  13.2

  	
   

  	
  Performance Liquidated Damages

  	
  55

  
	
   

  	
   

  	
   

  	
   

  
	
  13.3

  	
   

  	
  Performance Bonus

  	
  55

  
	
   

  	
   

  	
   

  	
   

  
	
  13.4

  	
   

  	
  Payment

  	
  55

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 14– WARRANTY

  	
  56

  
	
   

  	
   

  	
   

  	
   

  
	
  14.1

  	
   

  	
  Equipment

  	
  56

  
	
   

  	
   

  	
   

  	
   

  
	
  14.2

  	
   

  	
  Services Warranty

  	
  60

  
	
   

  	
   

  	
   

  	
   

  
	
  14.3

  	
   

  	
  Warranty of Title

  	
  60

  
	
   

  	
   

  	
   

  	
   

  
	
  14.4

  	
   

  	
  Limitations and Disclaimers

  	
  61

  
	
   

  	
   

  	
   

  	
   

  
	
  14.5

  	
   

  	
  Extended Equipment Warranty

  	
  62

  
	
   

  	
   

  	
   

  	
   

  
	
  14.6

  	
   

  	
  Limitation on Warranty Liability

  	
  62

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 15– INDEMNITY

  	
  62

  
	
   

  	
   

  	
   

  	
   

  
	
  15.1

  	
   

  	
  Contractor Indemnity

  	
  62

  
	
   

  	
   

  	
   

  	
   

  
	
  15.2

  	
   

  	
  Owner’s Indemnity

  	
  63

  
	
   

  	
   

  	
   

  	
   

  
	
  15.3

  	
   

  	
  Intellectual Property Indemnity

  	
  63

  
	
   

  	
   

  	
   

  	
   

  
	
  15.4

  	
   

  	
  Owner’s Nuclear Incident Indemnity

  	
  64

  
	
   

  	
   

  	
   

  	
   

  
	
  15.5

  	
   

  	
  Indemnity Procedures

  	
  65

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 16– INSURANCE

  	
  66

  
	
   

  	
   

  	
   

  	
   

  
	
  16.1

  	
   

  	
  Phase I Insurance Requirements

  	
  66

  
	
   

  	
   

  	
   

  	
   

  
	
  16.2

  	
   

  	
  Phase II Insurance Requirements

  	
  67

  
	
   

  	
   

  	
   

  	
   

  
	
  16.3

  	
   

  	
  Provisions Applicable to all
  Coverages

  	
  69

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 17– LIMITATION OF LIABILITY

  	
  70

  
	
   

  	
   

  	
   

  	
   

  
	
  17.1

  	
   

  	
  No Consequential Damages

  	
  70

  
	
   

  	
   

  	
   

  	
   

  
	
  17.2

  	
   

  	
  Maximum Total Liability; Time Limitation

  	
  70

  
	
   

  	
   

  	
   

  	
   

  
	
  17.3

  	
   

  	
  Division of Liability

  	
  71

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 18– LIENS

  	
  71

  
	
   

  	
   

  	
   

  	
   

  
	
  18.1

  	
   

  	
  Liens

  	
  71

  

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

iii

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

TABLE
OF CONTENTS

 

(continued)

 

	
   

  	
   

  	
   

  	
  Page

  
	
   

  	
   

  	
   

  	
   

  
	
  18.2

  	
   

  	
  Discharge or Bond

  	
  71

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 19– PROPRIETARY DATA

  	
  72

  
	
   

  	
   

  	
   

  	
   

  
	
  19.1

  	
   

  	
  Protection of Owner Proprietary Data

  	
  72

  
	
   

  	
   

  	
   

  	
   

  
	
  19.2

  	
   

  	
  Protection of Contractor’s
  Proprietary Data

  	
  73

  
	
   

  	
   

  	
   

  	
   

  
	
  19.3

  	
   

  	
  Special Procedures Pertaining to
  Contractor’s Proprietary Data

  	
  75

  
	
   

  	
   

  	
   

  	
   

  
	
  19.4

  	
   

  	
  Ownership of Rights in Documentation

  	
  79

  
	
   

  	
   

  	
   

  	
   

  
	
  19.5

  	
   

  	
  Ownership of Invention Rights

  	
  79

  
	
   

  	
   

  	
   

  	
   

  
	
  19.6

  	
   

  	
  Software

  	
  80

  
	
   

  	
   

  	
   

  	
   

  
	
  19.7

  	
   

  	
  Publicity

  	
  80

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 20– ENVIRONMENTAL; HAZARDOUS MATERIALS

  	
  80

  
	
   

  	
   

  	
   

  	
   

  
	
  20.1

  	
   

  	
  Material Safety Data Sheets

  	
  80

  
	
   

  	
   

  	
   

  	
   

  
	
  20.2

  	
   

  	
  Facility Use, Storage Removal

  	
  80

  
	
   

  	
   

  	
   

  	
   

  
	
  20.3

  	
   

  	
  Handling, Collection, Removal Transportation and Disposal

  	
  80

  
	
   

  	
   

  	
   

  	
   

  
	
  20.4

  	
   

  	
  Notice of Discovery

  	
  81

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 21– TITLE; RISK OF LOSS

  	
  81

  
	
   

  	
   

  	
   

  	
   

  
	
  21.1

  	
   

  	
  Transfer of Title

  	
  81

  
	
   

  	
   

  	
   

  	
   

  
	
  21.2

  	
   

  	
  Risk of Loss

  	
  81

  
	
   

  	
   

  	
   

  	
   

  
	
  21.3

  	
   

  	
  Risk to a Party’s Property

  	
  82

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 22– SUSPENSION AND TERMINATION

  	
  82

  
	
   

  	
   

  	
   

  	
   

  
	
  22.1

  	
   

  	
  Suspension by the Owner for Convenience

  	
  82

  
	
   

  	
   

  	
   

  	
   

  
	
  22.2

  	
   

  	
  Termination by Owner for Cause

  	
  83

  
	
   

  	
   

  	
   

  	
   

  
	
  22.3

  	
   

  	
  Termination by Owner for Convenience

  	
  84

  
	
   

  	
   

  	
   

  	
   

  
	
  22.4

  	
   

  	
  Suspension and Termination Due to Other Circumstances

  	
  84

  
	
   

  	
   

  	
   

  	
   

  
	
  22.5

  	
   

  	
  Termination by Contractor

  	
  86

  
	
   

  	
   

  	
   

  	
   

  
	
  22.6

  	
   

  	
  Actions Required of Contractor upon Termination

  	
  87

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 23– SAFETY; INCIDENT REPORTING

  	
  87

  
	
   

  	
   

  	
   

  	
   

  
	
  23.1

  	
   

  	
  Environmental, Health and Safety Programs

  	
  87

  
	
   

  	
   

  	
   

  	
   

  
	
  23.2

  	
   

  	
  Designated Contractor Safety Representative

  	
  87

  
	
   

  	
   

  	
   

  	
   

  
	
  23.3

  	
   

  	
  OSHA and Other Laws

  	
  88

  
	
   

  	
   

  	
   

  	
   

  
	
  23.4

  	
   

  	
  Worksite Safety

  	
  89

  

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

iv

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

TABLE
OF CONTENTS

 

(continued)

 

	
   

  	
   

  	
   

  	
  Page

  
	
   

  	
   

  	
   

  	
   

  
	
  23.5

  	
   

  	
  Dangerous Materials

  	
  89

  
	
   

  	
   

  	
   

  	
   

  
	
  23.6

  	
   

  	
  Cooperation in Governmental Investigations and Inspections

  	
  89

  
	
   

  	
   

  	
   

  	
   

  
	
  23.7

  	
   

  	
  Audit

  	
  89

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 24– QUALIFICATIONS AND PROTECTION OF ASSIGNED PERSONNEL

  	
  90

  
	
   

  	
   

  	
   

  	
   

  
	
  24.1

  	
   

  	
  Screening Measures

  	
  90

  
	
   

  	
   

  	
   

  	
   

  
	
  24.2

  	
   

  	
  Contractor’s Personnel

  	
  90

  
	
   

  	
   

  	
   

  	
   

  
	
  24.3

  	
   

  	
  Training of Employees

  	
  91

  
	
   

  	
   

  	
   

  	
   

  
	
  24.4

  	
   

  	
  NRC Whistleblower Provision

  	
  91

  
	
   

  	
   

  	
   

  	
   

  
	
  24.5

  	
   

  	
  Respirator Protection

  	
  91

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 25– RECORDS AND AUDIT

  	
  91

  
	
   

  	
   

  	
   

  	
   

  
	
  25.1

  	
   

  	
  Technical Documentation

  	
  91

  
	
   

  	
   

  	
   

  	
   

  
	
  25.2

  	
   

  	
  Accounting Records

  	
  92

  
	
   

  	
   

  	
   

  	
   

  
	
  25.3

  	
   

  	
  Maintenance of Records Generally

  	
  92

  
	
   

  	
   

  	
   

  	
   

  
	
  25.4

  	
   

  	
  Right to Audit

  	
  92

  
	
   

  	
   

  	
   

  	
   

  
	
  25.5

  	
   

  	
  Sales Tax Records

  	
  92

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 26– TAXES

  	
  93

  
	
   

  	
   

  	
   

  	
   

  
	
  26.1

  	
   

  	
  Employment Taxes

  	
  93

  
	
   

  	
   

  	
   

  	
   

  
	
  26.2

  	
   

  	
  Sales and Use Taxes on Contractor Tools

  	
  93

  
	
   

  	
   

  	
   

  	
   

  
	
  26.3

  	
   

  	
  Sales and Use Tax on Equipment

  	
  93

  
	
   

  	
   

  	
   

  	
   

  
	
  26.4

  	
   

  	
  State Property Taxes

  	
  93

  
	
   

  	
   

  	
   

  	
   

  
	
  26.5

  	
   

  	
  Tax Indemnification

  	
  94

  
	
   

  	
   

  	
   

  	
   

  
	
  26.6

  	
   

  	
  Pollution Control Equipment Information

  	
  94

  
	
   

  	
   

  	
   

  	
   

  
	
  26.7

  	
   

  	
  Non-resident Contractor

  	
  94

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 27– DISPUTE RESOLUTION

  	
  94

  
	
   

  	
   

  	
   

  	
   

  
	
  27.1

  	
   

  	
  Claims

  	
  94

  
	
   

  	
   

  	
   

  	
   

  
	
  27.2

  	
   

  	
  Change Dispute

  	
  95

  
	
   

  	
   

  	
   

  	
   

  
	
  27.3

  	
   

  	
  Resolution by Negotiation

  	
  95

  
	
   

  	
   

  	
   

  	
   

  
	
  27.4

  	
   

  	
  Mediation

  	
  96

  
	
   

  	
   

  	
   

  	
   

  
	
  27.5

  	
   

  	
  Arbitration of Claims Falling Below the Threshold Amount

  	
  96

  

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

v

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

TABLE
OF CONTENTS

 

(continued)

 

	
   

  	
   

  	
   

  	
  Page

  
	
   

  	
   

  	
   

  	
   

  
	
  27.6

  	
   

  	
  Exclusive Resolution Procedures; Equitable Remedies

  	
  98

  
	
   

  	
   

  	
   

  	
   

  
	
  27.7

  	
   

  	
  Consent to Jurisdiction

  	
  98

  
	
   

  	
   

  	
   

  	
   

  
	
  27.8

  	
   

  	
  Continuation of Work

  	
  99

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 28– NOTICES

  	
  99

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 29– ASSIGNMENT

  	
  101

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 30– WAIVER

  	
  101

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 31– MODIFICATION

  	
  101

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 32– SURVIVAL

  	
  101

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 33– TRANSFER

  	
  101

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 34– GOVERNING LAW; WAIVER OF JURY TRIAL; CERTAIN FEDERAL LAWS

  	
  102

  
	
   

  	
   

  	
   

  	
   

  
	
  34.1

  	
   

  	
  Governing Law

  	
  102

  
	
   

  	
   

  	
   

  	
   

  
	
  34.2

  	
   

  	
  Waiver of Jury Trial

  	
  102

  
	
   

  	
   

  	
   

  	
   

  
	
  34.3

  	
   

  	
  Certain Federal Laws

  	
  102

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 35– RELATIONSHIP OF OWNER AND CONTRACTOR

  	
  102

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 36– THIRD PARTY BENEFICIARIES

  	
  102

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 37– REPRESENTATIONS AND WARRANTIES

  	
  103

  
	
   

  	
   

  	
   

  	
   

  
	
  37.1

  	
   

  	
  Representations and Warranties of Contractor

  	
  103

  
	
   

  	
   

  	
   

  	
   

  
	
  37.2

  	
   

  	
  Representations and Warranties of SCE&G and Santee Cooper

  	
  103

  
	
   

  	
   

  	
   

  	
   

  
	
  ARTICLE 38– MISCELLANEOUS PROVISIONS

  	
  104

  
	
   

  	
   

  	
   

  	
   

  
	
  38.1

  	
   

  	
  Rights Exclusive

  	
  104

  
	
   

  	
   

  	
   

  	
   

  
	
  38.2

  	
   

  	
  Severability

  	
  104

  
	
   

  	
   

  	
   

  	
   

  
	
  38.3

  	
   

  	
  Entire Agreement

  	
  105

  
	
   

  	
   

  	
   

  	
   

  
	
  38.4

  	
   

  	
  Counterparts

  	
  105

  

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

vi

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBITS

 

	
  Exhibit

  	
   

  	
  Description of Exhibit

  
	
  A

  	
   

  	
  Scope of Work/Supply
  and Division of Responsibilities

  
	
  B

  	
   

  	
  Contractor Organization
  Chart

  
	
  C

  	
   

  	
  Owner and Contractor
  Permits

  
	
  D

  	
   

  	
  Project Execution Plan
  Processes

  
	
  E

  	
   

  	
  Project Schedule

  
	
  F-1

  	
   

  	
  Milestone Payment
  Schedule

  
	
  F-2

  	
   

  	
  Payment Plan

  
	
  G

  	
   

  	
  Time and Materials
  Rates and Charges

  
	
  H

  	
   

  	
  Pricing

  
	
  I-1

  	
   

  	
  Toshiba Parent Guaranty

  
	
  I-2

  	
   

  	
  Shaw Parent Guaranty

  
	
  J

  	
   

  	
  Price Adjustment
  Provisions

  
	
  K

  	
   

  	
  Costs

  
	
  L

  	
   

  	
  Net Electric Guarantee
  Conditions and Load List

  
	
  M-1

  	
   

  	
  Software License

  
	
  M-2

  	
   

  	
  AP1000 Intellectual
  Property License (WEC)

  
	
  M-3

  	
   

  	
  AP1000 Intellectual
  Property License (S&W)

  
	
  N

  	
   

  	
  Industry Codes and
  Standards

  
	
  O-1

  	
   

  	
  Proprietary Data
  Agreement

  
	
  O-2

  	
   

  	
  List of Intellectual
  Property Subject to Third Party License Terms

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-vii-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Exhibit

  	
   

  	
  Description of Exhibit

  
	
  P-1

  	
   

  	
  Major Subcontractors

  
	
  P-2

  	
   

  	
  Subcontractors for Site
  Construction and Related Field Services

  
	
  Q

  	
   

  	
  Equipment with
  Owner-Designated Witness and Hold Points

  
	
  R

  	
   

  	
  Description of Site

  
	
  S

  	
   

  	
  EEO and Small Business
  Regulations

  
	
  T

  	
   

  	
  [Not Used]

  
	
  U

  	
   

  	
  OCIP Description

  
	
  V

  	
   

  	
  Limited Agency
  Agreement

  
	
  W

  	
   

  	
  Extended Equipment Warranty Special Terms

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-viii-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

ENGINEERING, PROCUREMENT AND CONSTRUCTION AGREEMENT

 

This ENGINEERING, PROCUREMENT AND CONSTRUCTION
AGREEMENT (the “Agreement”) is entered into as of the 23rd day of May, 2008
(the “Effective Date”), by and between SOUTH CAROLINA ELECTRIC & GAS
COMPANY (“SCE&G”), for itself and as agent for the South Carolina Public
Service Authority, a body corporate and politic created by the laws of South
Carolina (“Santee Cooper”) pursuant to the Limited Agency Agreement between
SCE&G and Santee Cooper dated May 23, 2008 attached hereto as Exhibit V
(the “Limited Agency Agreement”); and
a consortium consisting of WESTINGHOUSE ELECTRIC COMPANY LLC, a Delaware
limited liability company having a place of business in Monroeville,
Pennsylvania (“Westinghouse”), and STONE & WEBSTER, INC., a Louisiana
corporation having a place of business in Charlotte, North Carolina (“Stone &
Webster”). Except where the context otherwise requires, Westinghouse and Stone &
Webster hereinafter are individually referred to as a “Consortium Member” and
collectively as “Contractor”. Without limiting the authority of SCE&G to
act as agent on behalf of Santee Cooper as provided in Section 3.6(a) hereof,
references herein to “Owner” shall mean each of SCE&G and Santee Cooper.
Owner and Contractor may be referred to individually as a “Party” and
collectively as the “Parties”.

 

RECITALS

 

WHEREAS, Owner desires to develop, license,
procure and have constructed a nuclear-fueled electricity generation facility;

 

WHEREAS, Westinghouse is engaged in the business
of designing, developing and supplying commercial nuclear facilities and has
developed a pressurized water Nuclear Power Plant known as the AP1000 (the “AP1000
Nuclear Power Plant”) for which the U.S. Nuclear Regulatory Commission has
issued a Standard Design Certification in the form of a rule set forth in
Appendix D to 10 C.F.R. Part 52;

 

WHEREAS, Stone & Webster is engaged in
the business of designing and constructing industrial and power generation
facilities;

 

WHEREAS, Westinghouse and Stone &
Webster desire to assist Owner in the licensing of and to design, engineer,
procure, construct, and test one or two AP1000 Nuclear Power Plants and related
facilities, structures and improvements at the V.C. Summer station;

 

WHEREAS, Owner and Contractor now desire to
enter into this Agreement to provide for, among other things, the design,
engineering, procurement and installation of equipment and materials, and
construction and testing of the Facility;

 

NOW,
THEREFORE, in
consideration of the recitals, the mutual promises herein and other good and
valuable consideration, the receipt and sufficiency of which the Parties
acknowledge, the Parties, intending to be legally bound, stipulate and agree as
follows:

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

ARTICLE
1 — DEFINITIONS

 

For purposes of this Agreement, the following words
and expressions shall have the meanings hereby assigned to them, except where
the context clearly indicates a different meaning is intended. These
definitions may be supplemented by any definitions contained in any of the
documents incorporated by reference herein, but in case of any conflict or
inconsistencies, the definitions set forth below shall prevail:

 

“AAA” means the American Arbitration Association.

 

“Additional Amount” has the meaning set forth in Section 22.4(d).

 

“AEA” means the Atomic Energy Act of 1954, as amended,
42 U.S.C. § 2011 et seq.

 

“Affiliate” means, with respect to any Party, any
other Person that (a) owns or controls, directly or indirectly, the Party,
(b) is owned or controlled by the Party, or (c) is under common
ownership or control with the Party, where “own”
means ownership of fifty percent (50%) or more of the equity interests or
rights to distributions on account of equity of the Party and “control” means the power to direct the
management or policies of the Party, whether through the ownership of voting
securities, by contract, or otherwise.

 

“Agreement” has the meaning set forth in the first
paragraph above and shall include all Exhibits, and amendments hereto
(including Change Orders).

 

“Ancillary Facilities” means the facilities,
structures and improvements at the Site that are within Contractor’s Scope of
Work as provided in Exhibit A but are not part of a Unit.

 

“AP1000 Facility Information” means the information
within Contractor’s Scope of Work, in the form of electronic databases,
documents, and drawings that pertain to Facility design, engineering,
licensing, analysis, installation, performance, testing, operation and
maintenance and shall be maintained by Contractor.  Collectively, this information, either
directly or by reference, shall reflect the current approved AP1000 Nuclear
Power Plant associated with Contractor’s Scope of Work at any point in time. A
portion of this information, as defined in Exhibit A, shall be
provided to Owner via an Information Management System (IMS).

 

“AP1000 Nuclear Power Plant” has the meaning set forth
in the Recitals.

 

“Arbitral Panel” has the meaning set forth in Section 27.5(b).

 

“Bankruptcy Code” means the United States Bankruptcy
Code, Title 11 of the United States Code.

 

“Business Day” means every calendar day other than
Saturday, Sunday or a legal holiday recognized by the State of South Carolina.

 

“CCIP” has the meaning set forth in Section 16.2(a).

 

“Chairman” has the meaning set forth in Section 27.5(b).

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-2-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

“Change” has the meaning set forth in Section 9.1.

 

“Change Dispute” has the meaning set forth in Section 27.2.

 

“Change Dispute Notice” has the meaning set forth in Section 27.2.

 

“Change in Law” means (a) any adoption or change,
after the Effective Date, of or in the judicial or administrative
interpretation of any Laws (excluding any Laws relating to net income Taxes),
which is inconsistent or at variance with any Laws in effect on the Effective
Date, (b) the imposition after the Effective Date of any requirement for a
new Governmental Approval or (c) the imposition after the Effective Date
of any condition or requirement (except for any conditions or requirements
which result from the acts or omissions of Contractor or any Subcontractor) not
required as of the Effective Date affecting the issuance, renewal or extension
of any Government Approval; that, in each case, is germane to the obligations
of the Parties set forth in this Agreement.

 

“Change Order” means the written agreement regarding a
Change contemplated by Section 9.4.

 

“Claim” has the meaning set forth in Section 27.1.

 

“Combined License” or “COL” means the combined
construction and operating license issued pursuant to 10 C.F.R. Part 52
for the Facility.

 

“Combined License Application” or “COLA” means the COL
application for the Facility at the Site that has been submitted to the NRC, as
such application may be updated or changed from time to time.

 

“Consortium Member” has the meaning set forth in the
opening paragraph of this Agreement.

 

“Construction and Installation Tests” means the tests
conducted as provided in Section 11.2.

 

“Construction Equipment” means equipment, machinery,
materials and/or test equipment used in the excavation, civil work,
mechanical/electrical installation and/or testing of the Facility, until such
equipment is no longer needed for tasks associated with Contractor’s Scope of
Work, and which shall not become a permanent part of the Facility.

 

“Contract Price” means [**].

 

“Contractor” has the meaning set forth in the opening
paragraph of this Agreement.

 

“Contractor Disclosable Information” has the meaning
set forth in Section 19.3(a).

 

“Contractor Interests” means Contractor and its (or
their) members, and its (or their) respective Affiliates, successors and
assigns, including any tier of the foregoing, its (or their) Subcontractors
(including suppliers) of any tier, and employees of all the foregoing, this
being limited to any activity connected in any way with this Agreement.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-3-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

“Contractor Non-Disclosable Information” has the
meaning set forth in Section 19.3(a).

 

“Contractor Permits” means the Governmental Approvals
identified as Contractor Permits in Exhibit C.

 

“Contractor’s Project Director” means the Person whom
Contractor designates in writing to administer this Agreement on behalf of
Contractor.

 

[**]

 

“Credit Rating” has the meaning set forth in Section 8.6(b).

 

“Day” as used in the Agreement means a calendar day
and includes Saturdays, Sundays and legal holidays.

 

“Delay Liquidated Damages” has the meaning set forth
in Section 13.1.

 

“Design Control Document” or “DCD” means the revision
of the AP1000 Nuclear Power Plant Design Control Document, APP-GW-GL-700, that
is in effect as of the Effective Date.

 

“Documentation” means the documents that Contractor
has agreed to provide in its Scope of Work as set forth in Exhibit A.

 

“DOE” means the U.S. Department of Energy and its
staff.

 

“Effective Date” means the date of this Agreement
first above written.

 

“Employment Taxes” has the meaning set forth in Section 26.1.

 

“Equipment” means machinery, computer hardware and its
associated software, apparatus, components, articles, materials, systems and
structures, and items of any kind that shall become a permanent part of the
Facility to be provided by Contractor to Owner under this Agreement, but
excluding the Nuclear Fuel.

 

“Equipment Warranty” has the meaning set forth in Section 14.1(a)(i).

 

“Exhibit” means each one of the documents Exhibit A
through W annexed to this Agreement.

 

“Existing
Confidentiality Agreement” has the meaning set forth in Section 19.2(c)(i).

 

“Extended Equipment Warranty” has the meaning set
forth in Section 14.5.

 

“Extended Equipment Warranty Period” has the meaning
set forth in Section 14.5.

 

“Facility” means the Unit or Units and the Ancillary
Facilities, and is more fully described in Exhibit A.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-4-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

“Facility Documentation” means the Documentation of
the applicable Consortium Member plus, if not included within the
Documentation, material and information within the possession or control of
such Consortium Member or its Subcontractors and that Consortium Member has the
right to transfer, sublicense or pass-through[**].  Facility Documentation does not include software or
its associated documentation that is the subject of Exhibit M-1,
Software License.

 

“Facility Manuals” means those manuals provided by
Contractor for use by the Operator in connection with the operation and
maintenance of the Facility.

 

“Facility Purposes” has the meaning set forth in Section 19.2(b)(i).

 

“Field Change” means a non-material change made to
support installation that does not require a change to P&IDs, one-line
electrical diagrams or the equipment arrangement drawings.  Field changes are not contrary to the COL or
the DCD, and are determined through a technical evaluation not to adversely
affect the form, fit or function of the system, structure or component.

 

“Final Completion” means that a Unit has achieved all
the conditions set forth in Section 12.6.

 

“Final Completion Punch List” has the meaning set
forth in Section 12.5.

 

“Final Payment Invoice” has the meaning set forth in Section 8.3.

 

[**]

 

[**]

 

[**]

 

“Full Notice to Proceed” means the written notice that
Owner gives to Contractor authorizing Contractor to proceed with the remainder
of the Work, subject to the limitations set forth in Section 3.2(b).

 

“G&A” means Stone & Webster’s general and
administrative costs as set forth in Exhibit G.

 

“Good Industry Practices” means any of the practices, methods,
standards and acts engaged in and generally acceptable to the nuclear power
industry in the United States that, at a particular time, in the exercise of
reasonable judgment in light of the facts known at the time a decision

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-5-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

was made could have been expected to accomplish the
desired result consistent with good business practices, reliability, economy
and safety.

 

“Government Approval” means any authorization,
consent, approval, clearance, license, ruling, permit, tariff, certification,
exemption, filing, variance, order, judgment, no-action or no-objection
certificate, certificate, decree, decision, declaration or publication of,
notices to, confirmation or exemption from, or registration by or with any
Government Authority relating to the design, engineering, procurement,
construction, testing, financing, completion, ownership or operation of the
Facility.

 

“Government Authority” means any federal, state,
county, city, local, municipal, foreign or other government or
quasi-governmental authority or any department, agency, subdivision, court or
other tribunal of any of the foregoing that has jurisdiction over Owner,
Contractor, the Facility or the activities that are the subject of this
Agreement.

 

“Guaranteed Substantial Completion Date” for a Unit
means the date set forth for such event in the Project Schedule as such date
may be extended due to a Change or otherwise pursuant to the terms hereof.

 

“Hazardous Materials” means any substance or
material regulated or governed by any Governmental Authority, or any substance,
emission or material now or hereafter deemed by any court or Government
Authority having jurisdiction to be a “regulated substance”, “hazardous
substance”, “toxic substance”, “pesticide”, “hazardous waste”, or any
similar classification, including by reason of deleterious properties,
ignitability, corrosivity, reactivity, carcinogenicity, or reproductive
toxicity, and shall include those substances defined as a “source”, “special
nuclear” or “by-product” material pursuant to Section 11 of the AEA (42
U.S.C. Section 2014 et seq.) and those
substances defined as “residual radioactive material” in Section 101 of
the Uranium Mill Tailings Radiation Control Act of 1978 (42 U.S.C. Sections
7901 et  seq.).

 

“Hold Point” means a critical step in a manufacturing
or testing process beyond which Contractor or a Subcontractor cannot
proceed except pursuant to the provisions in Section 5.6.

 

“House Loads” means those loads which receive power
from the low voltage side of the main step-up transformer and the unit
auxiliary transformers.

 

“Industry Codes and Standards” means the codes and
standards set forth in Exhibit N.

 

“Insolvent” means, with respect to a Person, that
such Person (i) makes any general assignment or any general
arrangement for the benefit of creditors, (ii) files a petition or
otherwise commences, authorizes, defaults as to or acquiesces in the
commencement of a case, petition, proceeding or cause of action under any
bankruptcy, insolvency or similar law for the protection of debtors or
creditors, or has such a case, petition, proceeding or cause of action
involuntarily filed or commenced against it and such case, petition, proceeding
or cause of action is not withdrawn or dismissed within sixty (60) Days after
such filing, (iii) otherwise becomes adjudicated a debtor in bankruptcy or
insolvent (however evidenced), (iv) is unable (or admits in writing its
inability) generally to pay its debts as they become due, (v) is dissolved
(other than pursuant to a consolidation, acquisition, amalgamation or merger), (vi) has
a resolution passed

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-6-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

for its winding-up, official management or liquidation
(other than pursuant to a consolidation, acquisition, amalgamation or merger), (vii) seeks,
or becomes subject to the appointment of an administrator, provisional
liquidator, conservator, assignee, receiver, trustee, custodian or other
similar entity or official for all or substantially all of its assets, (viii) has
a secured party take possession of all or substantially all of its assets or
has a distress, levy, execution, attachment, sequestration or other legal
process levied, enforced or sued on or against all or substantially all of its
assets and such secured party maintains possession, or any such process is not
dismissed, discharged, stayed or restrained, in each case within sixty (60)
Days thereafter, (ix) causes or is subject to any event with respect to
which, under the applicable laws of any jurisdiction, said event has an
analogous effect to any of the events specified in clauses (i) to (viii) (inclusive);
or (x) takes any action in furtherance of, or indicating its consent to,
approval of, or acquiescence in, any of the foregoing acts.

 

“Invitees” means, with respect to a Person, such
personnel or other Persons as have been permitted entry onto the Site by such
Person.

 

“ITAAC” means the NRC inspections, tests and analyses
and their associated acceptance criteria which are approved and issued for the
Facility pursuant to 10 C.F.R. § 52.97(b)(1).

 

“Joint Test Working Group” has the meaning set forth
in Section 11.1(b).

 

“Labor Shortage” means that the number of
appropriately skilled, qualified, trained and experienced personnel sufficient
to maintain the Project Schedule is not available at cost acceptable to Owner
where the Work is to be completed.

 

“Law” means (a) any constitution, statute, law,
rule, regulation, code, treaty, ordinance, judgment, decree, writ, order,
concession, grant, franchise, license, agreement, directive,  requirement, or other governmental
restriction or any similar form of decision of or determination by, or any
binding interpretation or administration of any of the foregoing by, any
Government Authority, whether now or hereafter in effect or (b) any
requirements or conditions on or with respect to the issuance, maintenance or
renewal of any Government Approval or applications therefore, whether now or
hereafter in effect.

 

“Licensing Basis” means the NRC requirements
applicable to the Facility as set forth in, until such time as the COL is
issued, the DCD and, upon its issuance, the COL.

 

“Lien” means any lien, mortgage, pledge, encumbrance,
charge, security interest, option, right of first refusal, other defect in
title or other restriction of any kind or nature.

 

“Limited Agency Agreement” has the meaning set forth
in the opening paragraph of this Agreement.

 

“Limited Notice to Proceed” means the written notice
that Owner gives to Contractor authorizing Contractor to proceed with the Work
in a limited manner in accordance with Section 3.2(a).

 

“Long Lead Material Payment” means the initial payment
equal to [**] received by Contractor from Owner for [**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-7-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

[**].

 

“Maintenance Procedures” means the procedures, written
or electronic, required to perform predictive, corrective, and preventive
maintenance of the Facility systems, components and structures, and those
procedures required for calibration and testing of instrumentation and
measurement systems and other components that are required for operation and
maintenance of the Facility.

 

“Major Equipment” means the following equipment: steam
generators, reactor vessel and reactor vessel head, control rod drive
mechanisms, main turbine, main turbine generator, turbine deaerator, reactor
coolant pumps, containment vessel, cooling towers, main turbine condenser,
reactor internals, main step-up transformers, pressurizer, diesel generators,
feedwater pumps, circulating water pumps, polar crane, core makeup tanks,
moisture separator reheaters, and any other equipment for which the contract(s) with
the Subcontractor is for an amount in excess of [**] or that Owner and
Contractor agree shall be designated as Major Equipment.

 

“Major Equipment Purchase Order” has the meaning set
forth in Section 3.7(c)(i).

 

“Major Equipment Vendor” has the meaning set forth in Section 3.7(c)(i).

 

“Major Subcontract” means a contract with a Major
Subcontractor.

 

“Major Subcontractor” means the Subcontractors (or
category of Subcontractors) identified on Exhibit P-1. For the
avoidance of doubt, Major Subcontractors may include, but are not limited to,
suppliers of Major Equipment.

 

“Mandatory Spare Parts” means those items to be
identified in Exhibit A as Mandatory Spare Parts and required to
support initial plant startup and to perform routine maintenance of the
Equipment during the first two (2) years of plant operation.

 

“Maximum Liability Amount” has the meaning set forth
in Section 17.2.

 

“Member” has the meaning set forth in Section 27.5(b).

 

“Milestone” means an event or series of events in the
execution of the Work as set forth in Exhibit F-1.

 

“Milestone Payment” means the payment due with respect
to a completed Milestone.

 

“Milestone Payment Schedule” means the Milestone
Payment Schedule set forth in Exhibit F-1.

 

“Net Unit Electrical Output” means the electrical
power of the Unit measured at the high side of the step-up transformer, with
the conditions as stated in Exhibit L.

 

“Net Unit Electrical Output Guarantee” has the meaning
set forth in Section 11.6.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-8-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

“Net Unit Electrical Output Test” has the meaning set
forth in Section 11.5(b).

 

“NRC” means the U.S. Nuclear Regulatory Commission and
its staff.

 

“Non-Standard Plant” means the portions of the
Facility that are not part of the Standard Plant.

 

“Nuclear Fuel” means fabricated nuclear fuel and
services meeting the principal design requirements referenced in the DCD.

 

“Nuclear Incident” means any occurrence that causes
bodily injury, sickness, disease or death, or loss of or damage to property, or
loss of use of property, arising out of or resulting from the radioactive,
toxic, explosive, or other hazardous properties of source material, special
nuclear material, or by-product material which is used in connection with the
operation of the Facility. “Source material”, “special nuclear material”, and “by-product
material”, as applicable to this Agreement shall have those meanings assigned
by the AEA.

 

“NuStart” means NuStart Energy Development, LLC.

 

“OCIP” has the meaning set forth in Section 16.2(a).

 

“Operating Procedures” means the procedures, written or
electronic, required to operate the AP1000 Nuclear Power Plant under normal,
abnormal, emergency, shutdown, or startup conditions.

 

“Operational Cycle” means, as to the first such cycle,
the time period from the first fueling of a Unit until the Unit has achieved
the conditions required to be met for performance of the Net Unit Electrical
Output Guarantee after the first Nuclear Fuel reload, and for subsequent
cycles, the time period from the end of an Operational Cycle until the
beginning of the next one. For the avoidance of doubt, the foregoing does not
mean that the Net Unit Electrical Output Test shall be re-performed at the end
of an Operational Cycle.

 

“Operator” means Operator of a Unit and/or the
Facility, it being understood that Contractor shall not be deemed to be the
Operator of a Unit and/or the Facility under any circumstances.

 

“Optional Spare Parts” means those items that may be
required to perform major maintenance of the Equipment, such as periodic
overhaul, or that could fail based on industry experience and for which
replacement parts may require longer lead times to obtain from the original
equipment manufacturers.

 

“OSHA” has the meaning set forth in Section 23.3.

 

“OSHA Standards” has the meaning set forth in Section 23.3(b).

 

“Other Customer” has the meaning set forth in Section 6.2.

 

“Owner” has the meaning set forth in the opening
paragraph of this Agreement.

 

“Owner Letter of Credit” has the meaning set forth in Section 8.6(d).

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-9-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

“Owner Permits” means the Government Approvals
identified as Owner Permits in Exhibit C.

 

[**]

 

“Owner’s Project Director” means the Person who Owner
designates in writing to act on behalf of Owner under this Agreement.

 

“P&IDs” means piping and instrumentation diagrams.

 

“Party” and “Parties” has the meaning set forth in the
opening paragraph of this Agreement.

 

“Payment Plan” has the meaning set forth in Section 8.1(a).

 

“Performance Bonus” has the meaning set forth in Section 13.3.

 

“Performance Liquidated Damages” means the liquidated
damages paid pursuant to Section 13.2 for failure to meet the Net Unit
Electrical Output Guarantee.

 

“Performance Liquidated Damages Cap” has the meaning
set forth in Section 13.2.

 

“Performance Test” means the tests conducted as
provided in Section 11.5.

 

“Person” means any individual, corporation, company,
partnership, joint venture, association, trust, unincorporated organization or
Government Authority.

 

“Personnel” means, with respect to a Person, such
Person’s employees, officers, directors, agents, personnel, representatives,
subcontractors of any tier (including, for Contractor, its Subcontractors),
vendors and any other third party independent contractors with whom such Person
has contracted.

 

“Phase I” means the portion of the Work described in Section 3.2(a).

 

“Phase II” means the portion of the Work described in Section 3.2(b).

 

“PQAP” has the meaning set forth in Section 5.1(a).

 

“PQAPIP” has the meaning set forth in Section 5.1(a).

 

“Preoperational Test Completion” has the meaning set
forth in Section 12.2(b).

 

“Preoperational Test Group” has the meaning set forth
in Section 11.3(b).

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-10-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

“Preoperational Tests” means the tests conducted as
provided in Section 11.3.

 

“Price Adjustment Provisions” means the terms set
forth in Article 7 and Exhibit J.

 

“Prime Rate” means, as of a particular date, the prime
rate of interest as published on that date in The Wall Street Journal, and
generally defined therein as “the base rate on corporate loans posted by at
least 75% of the nation’s 30 largest banks.” 
If The Wall Street Journal is not published on a date for which the
interest rate must be determined, the prime interest rate shall be the prime
rate published in The Wall Street Journal on the nearest-preceding date on
which The Wall Street Journal was published. 
If The Wall Street Journal discontinues publishing a prime rate, the
prime interest rate shall be the prime rate announced publicly from time to
time by Bank of America, N.A. or its successor.

 

“Pro Rata Profit” means the portion of the Profit that
is associated with a specific portion of the Work.

 

“Profit” means the aggregate of the Profit for each
Consortium Member for each element of the Contract Price as determined pursuant
to Section H.2.7 of Exhibit H as of the Effective Date.

 

“Project Execution Plan” means the plan to be
developed by Contractor and approved by Owner as provided in Section 3.5(h) setting
forth the processes and procedures that shall enable the Work to be managed in
an effective and efficient manner and in accordance with the requirements of
this Agreement.

 

“Project Schedule” means the schedule of key dates for
completion of the Work as set forth in Exhibit E.

 

“Proprietary Data” means the terms of this Agreement
and any and all information, data, software, matter or thing of a secret,
confidential or private nature relating to the business of the disclosing Party
or its Affiliates, including matters of a technical nature (such as know-how,
processes, data and techniques), matters of a business nature (such as
information about costs, profits, markets, sales, customers, suppliers, the
Parties’ contractual dealings with each other and the projects that are the
subject-matter thereof), matters of a proprietary nature (such as information
about patents, patent applications, copyrights, trade secrets and trademarks),
other information of a similar nature, and any other information which has been
derived from the foregoing information by the receiving Party; provided,
however, that Proprietary Data shall not include information which: (a) is
legally in possession of the receiving Party prior to receipt thereof from the
other Party; (b) the receiving Party can show by suitable evidence to have
been independently developed by the receiving Party or its employees,
consultants, affiliates or agents; (c) enters the public domain through no
fault of the receiving Party or others within its control; (d) is
disclosed to the receiving Party, without restriction or breach of an
obligation of confidentiality to the disclosing Party or (e) is legally
required to be disclosed; provided that the receiving Party subject to such a
requirement uses its reasonable best efforts to notify the other Party of any
request or subpoena for the production of any Proprietary Data and provides
such Party with an opportunity to resist such a request or subpoena.

 

[**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-11-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

“Quality Assurance Program” has the meaning set forth
in Section 5.1(a).

 

“Ready for Performance Test Date” has the meaning set
forth in Section 11.5(c).

 

“Ready for Startup Test Date” has the meaning set
forth in Section 11.4(c).

 

“Recipient” has the meaning set forth in Section 19.2(c)(i).

 

“Recoverable Costs” has the meaning described in Exhibit K.

 

“Sales Tax” means any sales, use or similar tax
imposed on Contractor, any Subcontractor or Owner with respect to the Work by
any Government Authority.

 

“Santee Cooper” has the meaning set forth in the
opening paragraph of this Agreement.

 

“SCE&G” has the meaning set forth in the opening
paragraph of this Agreement.

 

“Scope of Work” means the scope of work and supply and
division of responsibilities between Owner and Contractor set forth in Exhibit A.

 

“Screening Measures” has the meaning set forth in Section 24.1.

 

“Services” means all labor, transportation, packaging,
storage, designing, drawing, creating, engineering, demolition, Site
preparation, manufacturing, construction, commissioning, installation, testing,
equipping, verification, training, procurement, Documentation, licenses to
intellectual property or otherwise and other work, services and actions
(including pursuant to any warranty obligations) to be performed by Contractor
hereunder (whether at the Site or otherwise) in connection with, or relating
to, the Facility (or any component thereof, including any Equipment).

 

“Services Warranty” has the meaning set forth in Section 14.2.

 

“Services Warranty Period” has the meaning set forth
in Section 14.2.

 

“SGA” means Westinghouse’s sales, general and
administrative costs developed as provided in Section H.2.5 of Exhibit H.

 

“Shaw” means The Shaw Group, Inc.

 

“Site” means the premises (or portion thereof) owned
or leased by Owner on which the Facility shall be located, and including any
construction laydown areas, as more specifically described in Exhibit R.

 

“Software” has the meaning set forth in Exhibit M.

 

“Specifications” means the design specifications and
drawings, and changes thereto, prepared by Contractor or its Subcontractors for
the design, engineering and construction of the Facility.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-12-

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject
  to Restricted Procedures

  

 

“SSDs” has the meaning set forth in Section 19.3(b)(viii).

 

“Standard Equipment Warranty Period” has the meaning
set forth in Section 14.1(a)(ii).

 

“Standard Plant” means the plant design features and
buildings or structures in the scope of the AP1000 Nuclear Power Plant
certification as shown in the DCD Site Plan, Figure 1.2-2.

 

“Startup Test Completion” has the meaning set forth in
Section 12.3(b).

 

“Startup Test Group” has the meaning set forth in Section 11.4(b).

 

“Startup Tests” means the tests conducted as provided
in Section 11.4.

 

“Stone & Webster” has the meaning set forth
in the opening paragraph of this Agreement.

 

[**]

 

“Subcontract” means any contract, purchase order or
other writing between Contractor and any Subcontractor under which the
Subcontractor performs or provides any portion of the Work.

 

“Subcontractor” means (a) any Person other than
Contractor performing or providing any portion of the Work, whether hired
directly by Contractor or by a Person hired by Contractor and including every
tier of subcontractors, sub-subcontractors and so forth, and (b) any
Person providing or supplying all or a portion of the equipment or materials
and supplies required by any Person performing or providing any portion of the
Work to perform or provide the Work, whether or not incorporated into the
Facility, including, any materialman, vendor or supplier, whether hired
directly by Contractor or by a Person hired by Contractor and including every
tier of subcontractors, sub-subcontractors and so forth.

 

“Substantial Completion” means that a Unit shall have
achieved all the conditions set forth in Section 12.4.

 

“Substantial Completion Date” means the date on which
Substantial Completion has occurred.

 

“Target Price” means the portion of the Contract Price
identified as Target Price as set forth in Exhibit H, and as such
amount is adjusted pursuant to the terms hereof.

 

“Target Price Basis” means that Contractor shall be
compensated for the charges for Personnel, Services and Equipment, materials
and other expenses pursuant to Section H.2.2. of Exhibit H.

 

“Target Price Work” means Work performed on a Target
Price Basis.

 

“Taxes” means all present and future license,
documentation, recording and registration fees, all taxes (including income,
gross receipts, unincorporated business income, payroll, sales, use, personal
property (tangible and intangible), real estate, excise and stamp taxes),
levies, imports, duties, assessments, fees (customs or otherwise), charges and
withholdings of any nature whatsoever, and all penalties, fines, additions to
tax, and interest imposed by any Government Authority.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-13-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

“Technical Support” includes providing qualified
manpower and furnishing of technical guidance, advice and counsel with respect
to Owner or its Personnel at the Site, and includes recommending a course of
action with respect to Owner’s operation of a Unit or the Facility based upon
current design, engineering, construction and testing practices, but does not
include or require any supervision, regulation, control, arbitration or
measurement of Owner’s Personnel.

 

“Termination Costs” means with respect to a
termination under Section 22.3, 22.4, or 22.5, the aggregate of the
following costs: (a) for Westinghouse, (i) the Recoverable Costs, not
yet paid, that were incurred by Westinghouse prior to the date of notice of
termination and (ii) the Recoverable Costs incurred by Westinghouse to
bring the Work to an orderly conclusion, including the costs to demobilize and
cancel Equipment or material orders placed, and including but not limited to
cancellation charges paid by Westinghouse to third parties plus (iii) SGA
and Pro Rata Profit on the amounts in (i) and (ii), and (b) for Stone &
Webster, (i) any amounts, not yet paid, that are due for Work performed by
Stone & Webster prior to the date of notice of termination and (ii) charges
on a Time and Materials Basis incurred by Stone & Webster to bring the
Work to an orderly conclusion, including the costs to demobilize and cancel
Equipment or material orders placed, and including but not limited to
cancellation charges paid by Stone & Webster to third parties. All
such expenses, proceeds and payment shall be substantiated by documentation
reasonably satisfactory to Owner and subject to audit as set forth in Article 25.

 

“Third Party Claim” means any claim, demand or cause
of action of every kind and character by any Person other than Owner or
Contractor.

 

“Threshold Amount” means (i) for a monetary
Claim, that a Party has in good faith alleged that such Claim involves an
amount in controversy of greater than [**] and/or (ii) for a Claim
involving an adjustment to the Project Schedule, that a Party has in good faith
alleged that such Claim involves an adjustment to the Project Schedule in
excess of [**].  If a Claim alleges both
an amount and adjustment to the Project Schedule in controversy, such Claim
will fall below the Threshold Amount only if both (i) the amount in
controversy is equal to or less than [**]and (ii) the adjustment to the
Project Schedule in controversy is equal to or less than [**].

 

“Time and Materials Basis” means that Contractor shall
be compensated for the charges for Personnel and Equipment, materials and other
expenses pursuant to Section H.2.3 of Exhibit H, using the
rates and charges in Exhibit G.

 

“Time and Materials Charges” means the portion of the
Contract Price identified as Time and Materials Charges, as set forth in Exhibit H.

 

“Time and Materials Work” means Work performed on a
Time and Materials Basis.

 

“Toshiba” means Toshiba Corporation.

 

“Turnover” has the meaning set forth in Section 12.1(a).

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-14-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

“Uncontrollable Circumstance” means any event or
condition beyond the reasonable control of a Party despite its reasonable
efforts to prevent, avoid, delay or mitigate such acts, events or occurrences,
which prevents, impacts or delays a Party from performing its obligations under
this Agreement, including but not limited to the following:

 

(a)                                  An act of God, including landslide,
lightning, earthquake, fire, explosion, storm, flood, unusual or severe weather
conditions, including hurricanes, tornadoes; and any precautionary actions
taken in connection therewith;

 

(b)                                 Acts of a public enemy, war, blockade,
embargo, insurrection, riot or civil disturbance, sabotage or similar
occurrence or any exercise of the power of eminent domain, police power, any
act of terrorism, epidemic, condemnation or other taking by or on behalf of any
public, quasi-public or private entity; any strike or other concerted labor
actions; and any precautionary action or evacuation taken in connection with
any of the foregoing;

 

(c)                                  The suspension, termination,
interruption, denial, delay in obtaining or failure of renewal or issuance of
any Government Approval relating in any way to the Work or operation of the
Facility that is not the result of willful or negligent action by the Party
claiming the Uncontrollable Circumstance;

 

(d)                                 An order or other action by a Government
Authority [**];

 

(e)                                  Labor Shortage[**]; or

 

(f)                                    Delays due to accidents in shipping or
transportation provided that such accidents are not the result of negligence or
willful misconduct by the Party claiming Uncontrollable Circumstance.

 

[**]

 

“Unit” means each AP1000 Nuclear Power Plant to be
constructed hereunder at the Site. “First Unit” or “Unit 2” refers to the first
such Unit to be constructed and “Second Unit” or “Unit 3” refers to the second
such Unit to be constructed.

 

[**]

 

“Unit Mechanical Completion” has the meaning set forth
in Section 12.2(a).

 

“Warranties” means the obligations of Contractor under
Article 14.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-15-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

“Warranty” refers to either the Equipment Warranty or
the Services Warranty, as the case may be.

 

“Warranty Period” means the Standard Equipment
Warranty Period or Extended Equipment Warranty Period, as applicable.

 

“Westinghouse” has the meaning set forth in the
opening paragraph of this Agreement.

 

[**]

 

“Whistleblower Provisions” has the meaning set forth
in Section 24.4.

 

“Witness Point” means a critical step in a
manufacturing or testing process that is subject to witnessing by Owner or its
authorized representative in accordance with the procedures set forth in Section 5.6.

 

“Work” means the supervision, labor, Services,
material, equipment, tools, vehicles, transportation, storage, design,
engineering, procurement, site preparation, construction, installation,
equipping, testing, and other things and actions to be supplied by or through
Contractor necessary to furnish and install the Facility at the Site consistent
with Contractor’s Scope of Work and necessary to bring the Unit(s) to
Final Completion subject to and in accordance with the terms of this Agreement.

 

ARTICLE
2 — INTERPRETATION

 

A.                                   Titles,
headings, and subheadings of the various articles and paragraphs of this
Agreement are used for convenience only and shall not be deemed to be a part
thereof or be taken into consideration in the interpretation or construction of
this Agreement.

 

B.                                     Words importing
the singular only shall also include the plural and vice versa where the context requires.  Words in the masculine gender shall be deemed
to include the feminine gender and vice
versa.

 

C.                                     Unless the
context otherwise requires, any reference to a document shall mean such
document as amended, supplemented or otherwise modified and in effect from time
to time.

 

D.                                    Unless otherwise
stated, any reference to a party shall include its successors and permitted
assigns, and any reference to a Government Authority shall include any entity
succeeding to its functions.

 

E.                                      Wherever a
provision is made in this Agreement for the giving of notice, consent or
approval by any person, such notice, consent or approval shall be in writing,
and the word “notify” shall be construed accordingly.

 

F.                                      This Agreement
and the documentation to be supplied hereunder shall be in the English
language.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-16-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

G.                                     Unless the
context requires otherwise, with regard to general oversight of the Work,
review of the drawings and Specifications and other documents, access to the
Site and Work and other similar rights of Owner, the term Owner shall mean the
Owner’s Project Director or his designee. 
Unless the context requires otherwise any reference contained herein to
this Agreement or any other agreement or any schedule, Exhibit or
attachment hereto or thereto shall mean this Agreement or such other agreement
or such schedules, Exhibits and attachments, as they may be amended or
supplemented, unless otherwise stated.

 

H.                                    Words and
abbreviations not otherwise defined in this Agreement which have well-known
nuclear industry meanings in the United States are used in this Agreement in
accordance with those recognized meanings.

 

I.                                         Neither
Contractor nor Owner shall assert or claim a presumption disfavoring the other
by virtue of the fact that this Agreement was drafted primarily by legal
counsel for the other, and this Agreement shall be construed as if drafted
jointly by Owner and Contractor and no presumption or burden of proof shall
arise favoring or disfavoring any Party by virtue of the authorship of any of
the provisions of this Agreement.

 

J.                                        In the event
the due date for any payment falls on a day that is not a Business Day, payment
shall be due on the next Business Day.

 

ARTICLE
3 — SCOPE OF WORK

 

3.1                                 General.  Contractor
shall perform the Work identified as Contractor’s responsibility in the Scope
of Work (Exhibit A).  The
Work shall be performed in two phases, as more fully described in Section 3.2.  Owner, as licensee under the COL, shall be
ultimately responsible for the execution of all obligations and
responsibilities under such COL; provided, however, that the Parties agree and
acknowledge that Owner’s responsibility under the COL does not relieve
Contractor of any its obligations and responsibilities in the performance
of Contractor’s Work under the Agreement as described more fully herein.

 

3.2                                 Phases of the Work.

 

(a)                                  Phase I.  Phase I of
the Work shall consist of Contractor’s engineering support and other services
required by Owner to support Owner’s licensing efforts for the Facility
(including receipt of approvals from the Public Service Commission of the State
of South Carolina), continuation of design work (other than design work
performed under the NuStart program), project management, engineering and
administrative support to procure long lead time Equipment, the procurement of
long lead time Equipment, construction mobilization and Site preparation work,
all as more specifically described in Exhibit A. Phase I shall
commence upon the Effective Date and shall continue until the earlier of
issuance of the Full Notice to Proceed or termination of this Agreement in
accordance with Article 22; provided, however, that Phase I Site Work must
be authorized by Owner pursuant to one or more Limited Notices to Proceed. By
mutual agreement of the Parties as set forth in a Change Order issued pursuant
to Article 9, additional Site Work identified as part of Phase II in the
Scope of Work may be moved to Phase I and authorized by Owner to proceed by
means of an additional Limited Notice to Proceed.  In the event that any Phase I Work that was
commenced under separate

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-17-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

purchase orders between
Owner and one or both of the Consortium Members (the “Purchase Orders”) remains
to be completed as of the Effective Date, then as of June 1, 2008, the
Purchase Orders shall be terminated and the remaining work thereunder will be
subsumed by this Agreement.

 

(b)                                 Phase II.  Phase II of
the Work shall consist of the remainder of the Work as described in Exhibit A,
to commence upon issuance of a notice (the “Full Notice to Proceed”) and to
continue until Final Completion unless the Agreement is earlier terminated in
accordance with Article 22.  The
Parties acknowledge that the Full Notice to Proceed will not be issued unless
and until the COL is received.

 

3.3                                 Project Schedule.

 

(a)                                  A Project Schedule is attached to this
Agreement as Exhibit E.  The
Project Schedule includes milestones for key activities, such as the placement
of orders for long lead-time Equipment. Contractor shall update the Project
Schedule quarterly prior to the commencement of on-Site construction work and
monthly thereafter to reflect the most current information concerning the
scheduled Milestones and provide the updated Project Schedule to Owner for its
review and comment.  [**]  Subject to the preceding sentences, Changes
to the Guaranteed Substantial Completion date(s) shall be in accordance
with Article 9 of this Agreement.

 

(b)                                 If Owner desires to cancel the Second
Unit, it shall provide written notice of such intent to Contractor on or before
issuance of the Full Notice to Proceed. The Guaranteed Substantial Completion
Dates of the First Unit and Second  Unit
are April 1, 2016, and January 1, 2019, respectively.  The nuclear island concrete basemat shall be
poured prior to [**] on both Units. The Guaranteed Substantial Completion Dates
are based on a Full Notice to Proceed being received no later than [**] prior
to the Guaranteed Substantial Completion Date for the First Unit, at which time
first safety-related concrete must be placed. Prior to placing the first
safety-related concrete, preparatory work, including the mud mat and rebar
placement must be performed. Should the NRC review schedule for the COLA not
support this schedule, Contractor shall be entitled to a Change Order pursuant
to Article 9. In preparing such Change Order, the Parties will work toward
the goal of maintaining the Guaranteed Substantial Completion Dates as stated
above.

 

3.4                                 Not Used.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-18-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

3.5                                 Contractor Responsibilities.

 

(a)                                  Industry Standards. 
Subject to Article 9, Contractor shall perform and complete its
obligations under this Agreement in accordance with applicable Laws, this
Agreement, Industry Codes and Standards, and Good Industry Practices.  In the event of any conflict between any of
the authorities in the foregoing sentence, applicable Laws shall control over
the terms of this Agreement, Good Industry Practices and Industry Codes and
Standards; the terms of this Agreement shall control over Good Industry
Practices and Industry Codes and Standards; and Industry Codes and Standards
shall control over Good Industry Practices.

 

(b)                                 Contractor’s Key Personnel.  Exhibit B
contains a chart of Contractor’s intended organization for its performance
under this Agreement, including those positions to be designated as “key”
management for the performance of the Work. For such key management positions,
Contractor shall provide Owner with the resumes of the persons filling such
positions for Owner’s approval, which shall not be unreasonably withheld.  Once Owner has approved any such person,
Contractor shall not remove such person for its key management position
described in Exhibit B without Owner’s consent, which shall not be
unreasonably withheld.  If at any time
during the performance of the Work, any of Contractor’s personnel becomes, for
any reason, unacceptable to Owner, then, upon notice from Owner, Contractor
shall replace such unacceptable individual with an individual reasonably
acceptable to Owner. Contractor’s Project Director shall act as Contractor’s
liaison with Owner and shall have the authority to administer and manage this
Agreement on behalf of Contractor, subject to any limitations on such authority
notified by Contractor to Owner in writing.

 

(c)                                  AP1000 Facility Information. 
The AP1000 Facility Information shall be controlled and maintained by
Contractor for such period of time as is required pursuant to Contractor’s
Quality Assurance Program or, for information not covered by such Quality
Assurance Program in accordance with Contractor’s document retention
procedures.  The AP1000 Facility
Information shall contain Facility deliverable documents and information,
either directly or by reference. A means to access and print out documentation
and information in the AP1000 Facility Information shall be made available to
Owner through an information management system. Documentation required to be
provided to Owner as set forth in Exhibit A shall be provided in
accordance with the Project Schedule.

 

(d)                                 Control of Work. 
Contractor shall be solely responsible for all construction means,
methods, techniques, sequences, procedures, safety and quality assurance, and
quality control programs in connection with the performance of Contractor’s
Work. Under the conditions stated in Section 3.1 of this Agreement, Owner,
as licensee under the COL, shall be ultimately responsible for the execution of
all obligations and responsibilities under such COL. As such and under this
Agreement, Owner has delegated to Contractor the overall control and
implementation of all aspects of the Work. Accordingly, Contractor will develop
a Project Execution Plan as provided in Section 3.5(h) which will
identify all necessary interfaces between Contractor and Owner to assure that
each Party can adequately fulfill its respective responsibilities under this
Agreement and the applicable regulatory requirements.

 

(e)                                  Emergencies. 
In the event of any emergency endangering life or property, Contractor
shall take all actions as may be reasonable and necessary to prevent, avoid or
mitigate

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-19-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

injury, damage or loss
and shall promptly report each such emergency, and Contractor’s responses
thereto, to Owner.  In any event,
Contractor shall use commercially reasonable efforts to report an emergency to
Owner in sufficient time to allow Owner to make any required reports to any
Government Authority in accordance with applicable Laws.

 

(f)                                    Office Facilities. 
During construction, Contractor shall provide Owner with office
facilities on the Site as specified in Exhibit A.

 

(g)                                 Periodic Reports and Meetings.

 

(i)                                     Status Report.  On a monthly basis, Contractor shall submit
to Owner a written status report covering the prior month.  The report shall be prepared in a format
reasonably acceptable to Owner, and, for Work performed on a Time and Materials
Basis or Target Price Basis, shall be based on a time phased budget, at the
cost account level, against which program performance can be measured. The
report also shall include (w) a description of the progress of the Work, (x) a
statement of any significant issues which remain unresolved and Contractor’s
recommendations for resolving the same, (y) a summary of any significant
Facility events which are scheduled or expected to occur during the following
interval, and (z) additional information reasonably requested by
Owner.  The monthly report may be
delivered electronically.

 

(ii)                                  Attendance and Participation.  From the Effective Date until Final
Completion, Contractor shall attend and participate in regular meetings with
Owner which shall occur monthly (or upon such other interval as the Parties agree)
for the purpose of discussing the status of the Work and anticipating and
resolving any problems.  Such meetings
may be held by conference call or video conference. Contractor shall prepare
and promptly deliver to Owner written minutes of each meeting, to which Owner
shall respond in writing within a reasonable time if it has any comments.

 

(iii)                               Schedule Requirements;
Updates.  Contractor shall prepare and
make available to Owner following the Effective Date, at the Site or such other
location mutually agreed upon by the Parties, a current Project Schedule
depicting critical path activities and illustrating the progress which has been
made on the Work against such schedule, including critical path activities
interconnected by schedule logistics, for Owner’s review and comment.  Unless otherwise mutually agreed upon by the
Parties, Contractor shall revise and update the Project Schedule quarterly
prior to the commencement of on-Site construction work and monthly thereafter
and shall provide a copy to Owner, which may be provided electronically;
provided, however, that the Guaranteed Substantial Completion Dates for the
Units shall not be revised other than pursuant to Article 9. Portions of
the schedule may be updated weekly to provide information necessary to support
weekly invoices (if applicable).  Such
partial updates shall not be deemed to imply an update to the entire Project
Schedule.

 

(h)                                 Within sixty (60) Days following the
Effective Date, Contractor shall provide a Project Execution Plan as described
in Exhibit D to Owner for its review and approval.

 

(i)                                     Contractor shall provide Owner with
documentation to support Owner’s compliance with Federal Energy Regulatory
Commission and South Carolina Public Service

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-20-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Commission cost reporting
requirements. The detailed process to provide this documentation shall be
included in the Project Execution Plan, using the guidelines provided in Exhibit H.

 

3.6                                 Owner’s Responsibilities. 
Owner shall perform the responsibilities set forth in this Article and
elsewhere in this Agreement, including Exhibit A, at its own
expense and at those times as may be required by this Agreement for the successful
completion of the Work in accordance with the Project Schedule.

 

(a)                                  Appointment of Agent. 
Santee Cooper has appointed SCE&G as its agent pursuant to the
Limited Agency Agreement, which is attached hereto as Exhibit V,
for all purposes under this Agreement, with the power and authority to bind
Santee Cooper to its obligations herein, subject to the limitations
specifically set forth in the Limited Agency Agreement.  Owner shall notify Contractor promptly in
writing if there is any change in the limits of SCE&G’s authority set forth
in the Limited Agency Agreement. 
Contractor shall have the right to rely on any representation by
SCE&G that it has the authority to act on behalf of Santee Cooper with
respect to any and all matters pertaining to this Agreement, except with
respect to those matters where Santee Cooper’s prior written consent is
required under the Limited Agency Agreement.  With respect to those
matters set forth in the Limited Agency Agreement, where Santee Cooper’s prior
written consent is required, SCE&G shall provide Contractor with evidence
of Santee Cooper’s written consent to any actions taken by SCE&G in
connection with such matters.

 

(b)                                 Owner’s Representative. 
Owner shall appoint Owner’s Project Director (and shall have the right
to appoint any successor or replacement Project Director) with whom Contractor
may consult at all reasonable times, and whose instructions, requests and
decisions shall be binding upon Owner as to all matters pertaining to this
Agreement.

 

(c)                                  Access.  From and
after the time the Project Schedule indicates that Contractor is required to
have access to the Site, Owner shall provide Contractor, at no additional cost
to Contractor, rights of access to such portions of the Site as Contractor may
reasonably require for the construction of the Facility and for Contractor’s
office, warehouse, shop buildings, welding facilities, Contractor’s equipment
storage, laydown area, and employee parking. Owner shall cooperate with
Contractor so as to minimize disruption by Owner of Contractor’s performance of
the Work, and Contractor shall cooperate with Owner so as to minimize
disruption of operation of the Units and the existing unit at the Site.

 

(d)                                 Site Conditions and Site Parameters. Owner is responsible for all investigations
required to determine the suitability of the Site for the Facility. This
information has been furnished to Contractor. 
Contractor has conducted a reasonable visual inspection of the Site at
Owner’s expense and has notified Owner that there are no Site conditions that
were evident or readily discernible that shall affect the cost or schedule for
the construction of the Facility. Any subsurface or other site conditions
subsequently discovered at the Site or changes in the Site parameters that do
not conform to the information provided by Owner or were not evident or readily
discernible upon Contractor’s inspection shall entitle Contractor to a Change
Order pursuant to Article 9.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-21-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

(e)                                  Utilities, Consumables and Services. Owner shall provide the electrical
interconnect for power to be exported from the Facility at the interconnection
points identified or to be identified in Exhibit A. The Scope of
Work specifies the division of responsibilities between Owner and Contractor
for utilities during construction and for the supply of certain consumables and
services by Owner during construction and testing of the Facility.  All such items to be supplied by Owner shall
be supplied at the times required pursuant to the Project Schedule. Owner shall
provide all Nuclear Fuel.

 

(f)                                    Spare Parts.

 

(i)                                     Mandatory Spare Parts. Within
eighteen (18) months after finalization of the AP1000 Nuclear Power Plant
design as specified in the then current Project Schedule, Contractor shall
provide Owner with a list of spare parts for the Facility referred to as “Mandatory
Spare Parts.”  The Parties shall
determine a mutually agreeable price for such Mandatory Spare Parts, an
estimate for which has been provided in Exhibit H.  Mandatory Spare Parts will be provided on a
[**] unless otherwise agreed by the Parties. 
As part of Contractor’s Scope of Work, Contractor shall provide such
Mandatory Spare Parts to Owner by the completion of the Startup Tests or as
otherwise agreed to in the Project Schedule. 
All of the foregoing spare parts shall be considered to be parts
supplied to Owner under this Agreement, and title thereto shall pass to Owner
in accordance with Section 21.1. 
During the Warranty Period, Owner shall use commercially reasonable
efforts to maintain an inventory of spare parts equivalent to the Mandatory
Spare Parts and shall make such spare parts available to Contractor.

 

(ii)                                  Optional Spare Parts.  Within eighteen (18) months after finalization
of the AP1000 Nuclear Power Plant design as specified in the then current
Project Schedule, Contractor shall provide Owner with a list of Optional Spare
Parts that are recommended by Contractor and vendors of Equipment comprising
the Facility. At least two (2) years prior to the scheduled completion of
the Startup Tests or as otherwise agreed to in the Project Schedule, Owner
shall identify to Contractor the Optional Spare Parts which Owner wants
Contractor to procure.  Contractor
shall be entitled to a Change Order pursuant to Article 9 to cover the
additional costs of such Optional Spare Parts.  Owner shall
make such procured Optional Spare Parts available to Contractor for use during
its performance of the Work (as supplements for the
Mandatory Spare Parts procured by Contractor pursuant to Section 3.6(f)(i)).

 

(iii)                               Use and Replacement of Spare
Parts.  Contractor shall have the
right to use spare parts that are in Owner’s inventory specifically during the
performance of the Work or to remedy a Warranty item[**].  Contractor shall coordinate with Owner
concerning the delivery and storage of spare parts.

 

(g)                                 Operation and Maintenance Staff. 
For those activities supported and/or conducted by Owner under Articles
11 “Testing” and 12 “Stages of Completion”, Owner shall provide fully trained
and qualified operation and maintenance personnel for testing and operation

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-22-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

and maintenance of a Unit
or the Facility consistent with Contractor’s requirements as determined during
Phase I and as set forth upon such determination in Exhibit A. If
as a result of circumstances encountered during testing, Contractor determines
that additional operation and maintenance personnel are needed (and provided
that such determination has been made in accordance with Good Industry
Practices), Contractor shall have the right to require that additional
operation and maintenance personnel be provided by Owner upon reasonable
advance notice to, and following discussions with, Owner.

 

(h)                                 Job Site Rules. 
From the Effective Date until Final Completion of the Second Unit (or if
there is no Second Unit, the First Unit), each Party, its representatives and
agents shall abide by the Site safety rules promulgated by the other
Party.

 

3.7                                 Subcontractors.

 

(a)                                  Selection of Subcontractors. 
Contractor shall have the right to have portions of the Work performed
by Subcontractors. Subcontractors designated as Major Subcontractors are
identified in Exhibit P-1. 
After the Effective Date, Contractor shall provide periodic updates to
the Exhibit P-1 list and shall submit the updated list to Owner for
review. Owner shall identify to Contractor any added Major Subcontractors that
are unacceptable to Owner and provide to Contractor a reasonable basis for
Owner’s rejection of any such added Major Subcontractors. Exhibit P-2
contains a list of potential Subcontractors that may be used for Site
construction and related field services. 
Contractor shall work proactively with Owner to choose acceptable
Subcontractors for performance of the Work that is not part of the Standard
Plant.  In the event Contractor desires
to use any Subcontractors that are not listed in Exhibit P-2 to
conduct its Scope of Work on Owner’s property with respect to both the Standard
Plant and on work that is not part of the Standard Plant, Contractor shall
notify Owner and, within five (5) Business Days of such notice, Owner
shall notify Contractor if such proposed Subcontractor is not acceptable to
Owner (such acceptance not to be unreasonably withheld). If Owner rejects any
such selected Subcontractor and the use of a different Subcontractor would
affect Contractor’s costs for performance of the Work or the Project Schedule,
Contractor shall be entitled to a Change Order pursuant to Article 9. If,
however, Owner fails to provide such notice to Contractor within the five (5) Business
Day period, then Owner shall be deemed to have approved such proposed
Subcontractor. Subject to the prior provisions of this Section 3.7(a) with
respect to Major Subcontractors, Contractor is not obligated to consult with
Owner on its selection of Subcontractors not working on Owner’s property.  Owner shall have the right to recommend
additions to Exhibit P-1 and P-2 from time to time, subject
to Contractor’s approval. Contractor shall be responsible for the actions and
omissions of all Subcontractors.

 

(b)                                 [**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-23-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

[**]

 

(c)                                  Performance by Contractor and Major Equipment
Vendors; Owner’s Cure Rights.

 

(i)                                     Contractor warrants and
represents that it shall in good faith fully and promptly perform and observe
all of the agreements, terms, covenants and conditions required to be performed
and observed by the Contractor under any material provision of a Subcontract
for Major Equipment (a “Major Equipment Purchase Order”).  Upon demand, Contractor shall furnish to
Owner a certification that [**].

 

(ii)                                  Upon Contractor’s receipt of
the first payment from Owner for the purpose of procuring an item of Major
Equipment, Contractor shall designate the schedule reservation for such item of
Major Equipment to Owner and thereafter [**].

 

(iii)                               [**]

 

(iv)                              If Contractor is in default
of a payment obligation pursuant to a Major Equipment Purchase Order, Owner may
make the applicable payment due and owing

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-24-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

under such Major
Equipment Purchase Order in order to cure such payment default; provided,
however, that Owner shall not make such payment if, and so long as (a) Contractor
shall take all steps necessary to challenge or take any action to cure such
payment default; and (b) during such challenge or cure: (i) the
interests of Owner may not be materially adversely affected, (ii) no time
limits or grace periods under the Major Equipment Purchase Order would expire
which would give Major Equipment Vendor any right or option to terminate the
Major Equipment Purchase Order, and (iii) no additional right or remedy
would become available to the Major Equipment Vendor by reason of the deferral
by Owner of any action to effect a cure of the payment default.  [**]

 

(d)                                 Owner’s Consent for Termination or
Modification of Major Equipment Purchase Orders.

 

(i)                                     [**]

 

(ii)                                  [**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-25-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

[**]

 

(e)                                  [**]

 

(f)                                    Subcontract Terms. Contractor shall use commercially
reasonable efforts to include in each Major Equipment Purchase Order provisions
in substantially the following form for the protection of Owner. If Contractor
is unable to obtain such agreement in advance from a Major Equipment Vendor, it
shall promptly notify Owner; however, in the event that this Agreement is
terminated, Contractor shall work cooperatively with Owner to obtain the
agreement of the Major Equipment Vendor to assignment of its Subcontract or the
relevant portion thereof at that time. It should be noted that the Subcontracts
that Contractor will have with ABB Ltd. and Emerson Process Management for the
supply of instrumentation and control related equipment associated with the
Work will not be directly assignable to Owner in the event of termination of
this Agreement.

 

(i)                                     Major Equipment Vendor
agrees that upon termination of the Agreement between Contractor and Owner for
any reason other than Owner’s default or Owner’s termination for convenience,
Owner, or its nominee, shall have the option to [**] under this Major Equipment
Purchase Order related to Owner scope of supply.

 

(ii)                                  [**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-26-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

[**]

 

(iii)                               [**]

 

(iv)                              [**]

 

(v)                                 Title to an item of Major Equipment shall
pass to Contractor upon payment in full by Contractor to the Major Equipment
Vendor for such item of Major Equipment.

 

ARTICLE 4 — FACILITY LICENSES, PERMITS AND APPROVALS

 

4.1                                 Owner Permits. 
Owner shall be responsible for obtaining, maintaining and paying for
Owner Permits (including the COL) and for all communications with any
Government Authorities regarding such Government Approvals.  Contractor shall provide support to Owner in
connection with such Government Approvals, including making personnel available
to testify at formal and informal government proceedings, and providing all
documents and information reasonably requested by Owner, including review and
comment to sections prepared by others, and any amendments thereto, to address
formal NRC licensing questions on a schedule that supports the Project Schedule
and licensing support services. 
Contractor shall be compensated for such services on a Time and
Materials Basis.  Owner shall provide as
much advance notice as practical for the testimony of Contractor’s Personnel at
proceedings before

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-27-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Government Authorities. Contractor provides no
assurance or guarantee that the COL or any other Owner Permit required to be
obtained by Owner shall be obtained by Owner.

 

4.2                                 Contractor Permits. 
Contractor shall be responsible for obtaining, maintaining and paying
for the Contractor Permits. Owner shall provide Contractor reasonable
cooperation and assistance in obtaining and maintaining Contractor Permits.

 

4.3                                 ITAACs.

 

(a)                                  Contractor shall be responsible for those
ITAACs associated with each Unit as are set forth in the Design Control
Document.  Any new or additional ITAAC,
or any changes or modification to the ITAAC contained in the Design Control
Document that Owner proposes be added to Contractor’s Scope of Work shall be
subject to agreement by Contractor and Owner pursuant to Section 9.1(a) and,
upon such agreement, shall entitle Contractor to a Change Order pursuant to Article 9.

 

(b)                                 Contractor shall be responsible for
conducting, or causing to be conducted the inspections, tests and analyses
associated with each Unit’s ITAAC within Contractor’s Scope of Work. Upon
completion of such inspections, tests and analyses, Contractor shall be
responsible for preparing and delivering to Owner the Documentation or other
deliverables to demonstrate and confirm that the related acceptance criteria
associated with such inspections, tests and analyses as applicable to each Unit
within Contractor’s Scope of Work have been met.

 

ARTICLE
5 — QUALITY ASSURANCE

 

5.1                                 Quality Assurance.

 

(a)                                  Contractor has sole responsibility for
the quality assurance and quality control of the Work.  Contractor has provided to Owner its quality
assurance program consisting of each Consortium Member’s Quality Assurance
Program that has been approved by the NRC (“Quality Assurance Program”).  The Quality
Assurance Program and any changes thereto shall meet the requirement of 10
C.F.R. Part 50, Appendix B and ASME NQA-1 – 1994 and be accepted by the
NRC and accepted by Owner.  Contractor’s
Quality Assurance Program is subject to review and audit by Owner for
compliance with 10 C.F.R. Part 50 Appendix B and ASME NQA-1 - 1994.  Contractor has prepared AP1000
Project-specific clarifications and modifications with respect to the Quality
Assurance Program and has set forth such items in the Project Quality Assurance
Program Interface Plan (“PQAPIP”).  The
PQAPIP will be included in the Project Execution Plan and shall be delivered to
Owner for its review and approval. Owner’s review and acceptance of the PQAPIP
shall not relieve Contractor from its obligations to comply with the
requirements of this Agreement and 10 C.F.R. Part 50, Appendix B.  The Quality Assurance Program and the PQAPIP
will collectively be the “Project Quality Assurance Program” or “PQAP”.  Contractor shall provide Owner with five (5) copies
of the PQAP and Quality Assurance Program or make them available
electronically. Contractor shall follow the PQAP throughout its performance of
the Work.  The PQAP and associated
policies and procedures shall address Contractor’s Scope of Work, including,
without limitation, systems, structures and components in a manner consistent
with their classification with respect to their importance to nuclear safety
(i.e., safety related, important to safety, non-safety related) or their

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-28-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

importance to the capacity, operability and reliability of the Facility as
classified in the DCD.  The PQAP shall
support Owner’s compliance with 10 C.F.R. Part 50, Appendix B and ASME NQA-1
– 1994 and shall be subject to review and audit
by the Owner at the Owner’s request.  For
purposes of the American Society of Mechanical Engineers (ASME) Code,
Contractor shall be designated as Owner’s agent.

 

(b)                                 Subcontractor Quality Assurance. 
In accordance with the PQAP, Contractor shall also require Major
Subcontractors to establish, implement and maintain appropriate quality
assurance programs (which may either be the PQAP or such other quality
assurance program capable of being audited to the requirements of the PQAP) for
their respective portions of the Work consistent with the nuclear safety
quality classification of their portion of the Work.  Such programs shall be made available for
review by Owner.  Major Subcontractor
audit reports shall be made available for review by Owner or its authorized
representative.  At its own cost, Owner
or its authorized representative may participate in scheduled audits of
Subcontractors performed by Contractor.

 

5.2                                 Reporting of Defects, Noncompliance,
Failures and Breakdowns of QA Programs.  Contractor
shall comply with the provisions of 10 C.F.R. Part 21, “Reporting of
Defects and Noncompliance,” and 10 C.F.R. Part 50.55, “Conditions of
construction permits, early site permits, combined license, and manufacturing
licenses,” in the performance of its obligations under this Agreement.  Without limiting the foregoing, Contractor
shall act as the “dedicating entity,” as defined in 10 C.F.R. § 21.3 and 10
C.F.R. § 50.55(e)(1), and comply with the requirements of 10 C.F.R. § 21.21(c) and
10 C.F.R. § 50.55(e)(4).  Contractor
shall comply with the posting requirements of 10 C.F.R. § 21.6 and 10 C.F.R. §
50.55 at the Site and shall permit, and cause each Subcontractor to permit, the
NRC to inspect records, premises, activities and basic components as necessary
to accomplish the purposes of 10 C.F.R. Part 21, including permitting the
NRC the opportunity to inspect records pertaining to basic components that
relate to the identification and evaluation of deviations, and the reporting of
defects and failures to comply, including any advice given to purchasers or
licensees on the placement, erection, installation, operation, maintenance,
modification, or inspection of a basic component.  Contractor shall comply with the provisions
of 10 C.F.R. § 50.55(e)(1)(iii)(C) for reporting any significant breakdown
in any portion of the Contractor’s or Subcontractor’s quality assurance program
conducted under the requirements of Appendix B to 10 C.F.R. Part 50 which
could have produced a defect in a basic component.  Contractor shall require in each contract
with its first tier Subcontractors to perform any of the Services or to furnish
any Equipment, at the Site or elsewhere, and that are subject to the provisions
of 10 C.F.R. Part 21 and 10 C.F.R. 50.55, that such Subcontractor shall
comply with the provisions of 10 C.F.R. Part 21 and 10 C.F.R. Part 50.55.
Additionally, Contractor shall require that each Subcontractor include in each
contract with its first tier Subcontractors to perform any of the Services or
to furnish any Equipment, at the Site or elsewhere, and that are subject to the
provisions of 10 C.F.R. Part 21 and 10 C.F.R. Part 50.55 a provision
stating that such Subcontractor shall comply with the provisions of 10 C.F.R. Part 21
and 10 C.F.R. Part 50.55. 
Contractor shall, and shall require that each of its first tier
Subcontractors, provide Owner with copies of all notices and other
documentation that Contractor or such Subcontractor, as applicable, may disclose
to the NRC pursuant to 10 C.F.R. Part 21 or 10 C.F.R. Part 50.55
concurrently with such disclosure to the NRC (or, if concurrent disclosure is
not practical, as soon as reasonably practicable following such disclosure).

 

“[**]” in this Exhibit 10.01 indicates material
that has been omitted pursuant to a request for confidential treatment and
filed separately with the Securities and Exchange Commission.

 

-29-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Additionally, each Subcontractor shall require that
each of its first tier Subcontractors provide Owner with copies of all notices
and other documentation that such Subcontractor or its Subcontractors, as
applicable, may disclose to the NRC pursuant to 10 C.F.R. Part 21 or 10
C.F.R. Part 50.55 concurrently with such disclosure to the NRC (or, if
concurrent disclosure is not practical, as soon as reasonably practicable
following such disclosure).

 

5.3                                 Quality Control and Inspection Activities. 
Contractor shall be responsible to perform the quality control and
inspection activities in accordance with the PQAP.  The quality control and inspection activities
shall be consistent with the nuclear safety quality classification of the system,
structure or component under evaluation. 
The Persons performing quality assurance and control functions for
Contractor shall have sufficient authority and organizational freedom to
identify quality problems; to initiate, recommend, or provide solutions; and to
verify implementation of solutions.  Such
Persons performing quality assurance and control functions shall report to a
management level such that this required authority and organizational freedom,
including sufficient independence from cost and schedule when opposed to safety
considerations, are provided.

 

5.4                                 Access and Auditing at Contractor
Facilities.  Contractor shall provide Owner and its
authorized representatives with reasonable access during normal working hours
to the Work at Contractor’s facilities, and all pertinent documentation
relating to the Work, for observation and inspection, including auditing of
activities for conformance with the requirements of the PQAP and all
requirements of this Agreement. 
Inspections and audits of Contractor shall be coordinated with
Contractor.

 

5.5                                 Access and Audits at Subcontractors’
Facilities.  Contractor shall include in its Subcontracts
with Major Subcontractors the right of Owner to have access to such
Subcontractors’ facilities as follows. During working hours, Owner and its
authorized representatives shall have the right of access to Contractor’s and
Major Subcontractors’ premises and working facilities for quality assurance and
quality control activities.  Contractor
shall provide Owner and its authorized representatives with necessary
information and assistance to carry out Owner’s quality assurance and quality
control activities.  Quality assurance
and quality control activities at Major Subcontractors shall be limited to
participation in scheduled audits and execution of Witness Points identified as
the Witness Points and Hold Points in the manufacturing and fabrication plans
for the Equipment, such as in-process testing and final product review for
acceptance. Quality assurance and quality control activities at Major
Subcontractors include activities necessary to address quality issues which may
arise at sub-suppliers. In cases where Contractor incurs additional cost or delay in the Project Schedule from its
Major Subcontractors due to Owner’s request to perform additional quality
assurance and quality control activities beyond these activities, Contractor
shall be entitled to a Change pursuant to Article 9.  Contractor shall implement, and require its
Major Subcontractors to implement measures necessary to be taken to ensure
compliance with this Agreement where such measures are identified as a result
of a quality assurance audit or surveillance carried out by Owner’s authorized
representatives.  The rights of access
described above are subject to restrictions which may be identified by a Major
Subcontractor related to access to proprietary information, additional costs
for access beyond routine audits and Witness Points, reasons of national
security or access by foreign nationals.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-30-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

5.6                                 Witness and Hold Points.

 

(a)                                  Following the selection
of a specific vendor for Equipment identified in Exhibit Q that is
part of the Standard Plant and for which there are contractual Witness Points
and Hold Points, Contractor shall identify the associated Witness Points and
Hold Points via inclusion of the Witness Points and Hold Points in the
manufacturing and fabrication plans for the Equipment.  After review, Owner may identify additional
Witness Points and Hold Points and Owner shall notify Contractor of any
Owner-designated Witness Points or Hold Points that they shall attend.  In cases where Contractor incurs additional
cost or delay in the Project Schedule from its Major Subcontractors due to
Owner’s request to add additional Witness Points and/or Hold Points beyond
those identified by Contractor, Contractor shall be entitled to a Change Order
pursuant to Article 9. Contractor shall provide Owner access to or copies
of these manufacturing and fabrication schedules for Equipment identified in Exhibit Q
and the regular updates to these schedules, such that Owner has advance notice
of approaching scheduled Witness Points and Hold Points.  Owner shall be notified in writing by Contractor
of Owner-designated Witness Points and Hold Points as soon as practicable but
no later than [**] Business Days prior to the scheduled activity.  Owner shall acknowledge the notification of
Owner-designated Hold Points within [**] Business Days and indicate whether or not it intends to attend the
activity that is the subject of the Hold Point.

 

(b)                                 Work may proceed with
and beyond Owner-designated Witness Points in the absence of Owner’s or its
authorized representative’s participation without a written waiver. Work may
not proceed with or beyond Owner-designated Hold Points without a written
waiver from Owner.  If proper notification has been given and
Owner has responded that it intends to attend the activity that is the subject
of the Owner-designated Hold Point, but Owner or its authorized representative
is unavailable at the designated time, or Owner does not respond as to whether
or not it intends to attend the activity that is the subject of the
Owner-designated Hold Point, the work shall not proceed, Contractor shall be
entitled to a Change Order pursuant to Article 9.  Requests by
Owner to witness tests or conduct surveillance after the scheduled point in
time designated for a Witness Point or Hold Point shall be accommodated by
Contractor only if technically feasible, shall entitle Contractor to a Change
Order pursuant to Article 9.

 

(c)                                  Witnessing of tests or
other surveillance by Owner shall be at Owner’s expense. If Owner performs the
surveillance or elects not to perform a surveillance, such surveillance or
waiver shall not relieve Contractor of its obligations under this Agreement.

 

(d)                                 Any nonconformance or deviation from
design requirements for the Equipment listed in Exhibit Q which
results in “repair” or “accept as is” dispositions to design requirements shall
be submitted to Owner for its written approval, which shall not be unreasonably
withheld. Repaired and reworked items shall be re-inspected to verify
conformance to the requirements specified by the disposition. A nonconformance
which represents significant conditions adverse to quality submitted for Owner’s
approval shall include the identification of the cause of the nonconformance
and the corrective action to prevent recurrence.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-31-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

5.7                                 Owner’s Right to Inspect and Stop Work.

 

(a)                                  Owner’s Right to Inspect. 
Owner shall have the right to have its authorized representatives
inspect the Work in order to assure that the Work complies with the
requirements of this Agreement, including Contractor’s PQAP. Inspection by
Owner shall not be deemed to be supervision by Owner of Contractor and shall
not relieve Contractor of any responsibility for performing the Work in
accordance with this Agreement.  Any
acceptance or approval by Owner shall not be deemed to constitute final
acceptance of same by Owner, but shall be only for the purpose of assuring that
the Work complies with this Agreement. Owner may report to Contractor any
unsafe or improper conditions or practices observed at the Site for action by
Contractor in correction or enforcement.

 

(b)                                 Defective Work. 
If Owner’s inspection reveals any non-compliance or any other defects in
any portion of Work, then Contractor shall, promptly upon its receipt of notice
from Owner, take such actions as are required with respect to such defective
Work in accordance with its Quality Assurance Program.  If Contractor is not taking the actions
required with respect to defective Work in accordance with the PQAP, Owner
shall have the right to cause Contractor to take corrective action.

 

(c)                                  Right to Stop Work for Cause. 
If Contractor fails to take corrective action for defective Work as
required under Section 5.7(b), then Owner, by written order, may order
Contractor to stop performance of the portion of the Work affected thereby,
until the cause of such order has been eliminated.  In addition, Owner, by written order, may
order Contractor to stop performance if the activities of Contractor at the
Site reasonably appear to Owner to cause or threaten to cause danger to life or
damage to property. Contractor shall not be entitled to a Change Order for stop
Work orders properly issued pursuant to the terms of this Section 5.7(c).

 

(d)                                 Uncovering of Work. Prior to the commencement of the
Warranty Period, in the event Owner requests that any Work be uncovered to
determine whether it is deficient, Contractor shall be entitled to a Change
Order pursuant to Article 9 unless the Work is found to be deficient.  If the Work is found to be deficient,
Contractor shall repair or replace it or take other appropriate corrective
action. During the Warranty Period, the provisions of Article 14 shall
apply to any Work that does not conform to the Warranties.

 

ARTICLE 6 — CONTRACT PRICE

 

6.1                                 Components of the Contract Price. 
The Contract Price is divided by Unit and by Consortium Member, as
further described in Exhibit H. 
[**]

 

6.2                                 [**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-32-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

[**]

 

6.3                                 Future Fuel Agreement and Services
Agreement.

 

(a)                                  Westinghouse
and Owner intend to enter into negotiations for establishing a long term
services agreement and a fuel fabrication agreement, as provided below:

 

(i)                                     The services agreement would
be typical of existing alliance agreements that Westinghouse holds with its
existing customers and would be tailored to both Parties’ specific needs and
business objectives.  The contract
structure would contain provisions for agreed upon exclusive scopes and
preferred vendor scopes, and include provisions for price protections and
performance incentives based on Westinghouse and overall Unit performance.  The initial agreement would be for future
services on Units 1, 2 and 3, starting on a mutually agreeable schedule.

 

(ii)                                  The intent of the fuel fabrication agreement would provide
Westinghouse the fuel fabrication for a period through year [**], for Unit 1
fuel reloads beyond the current contract and the fuel fabrication for the first
core and future reloads on Units 2 & 3 through [**].

 

(iii)                               Throughout the development and negotiation of these agreements,
each of Owner and Contractor will evaluate its individual business case to
determine the prudency of entering into long term agreements.  At any point during this period, either Party
may terminate negotiations. In the event that Westinghouse and Owner have not,
on or before [**], entered into (x) services agreement for long term
services, and/or  (y) a fuel
fabrication agreement for long term fuel fabrication for Owner’s existing
nuclear power plant at the V.C. Summer station and the Units, (each such
agreement to be on mutually agreed terms and conditions) [**].

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-33-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

(b)                                 Owner shall use best efforts to engage
Shaw to perform certain maintenance services for Owner, provided that Shaw and Owner mutually agree to
commercially reasonable terms and conditions to govern Shaw’s performance of
such maintenance services.

 

ARTICLE 7 — PRICE ADJUSTMENT PROVISIONS

 

The amounts payable to
Contractor under this Agreement (other than the Fixed Price portion of the
Contract Price) shall be subject to the Price Adjustment Provisions described
in Exhibit J. [**]

 

ARTICLE 8 — PAYMENTS

 

8.1                                 Target Price
and Time and Materials Payments.

 

(a)                                  Payment for Target
Price.  Prior to the
commencement of any Target Price Work, Contractor shall provide to Owner a
projected payment plan, broken down by calendar quarter, for the remainder of
2008, and monthly thereafter, for the Target Price portion of the Contract
Price (the “Payment Plan”, to be appended to this Agreement as Exhibit F-2).  By Monday, 5:00 p.m. Eastern time of each week,
Contractor shall deliver to Owner an invoice (in electronic form) for the
Target Price Work based on costs  invoiced to Contractor or incurred by
Contractor due to hours worked or otherwise during the prior week.  Payment shall be due in the form of an
electronic transfer of funds from Owner to Contractor’s account by Thursday,
5:00 p.m. Eastern time  of such week.  On at
least a monthly basis, the Parties shall review the Payment Plan and the actual
documented costs incurred to determine whether changes are required to the
Payment Plan to account for any amounts over or under invoiced by Contractor.
The Payment Plan shall be revised and resubmitted to Owner by Contractor as a
result of such review.  In addition, cost
and schedule performance shall be evaluated on a monthly basis, the results of
which shall be provided to Owner, and corrective actions shall be developed to
remedy deficiencies identified by this review.

 

(b)                                 Payment for Time and
Materials Charges.  Unless otherwise agreed by the Parties, billings for Time
and Materials Work shall be subject to the same
procedures and payment processes as set forth in Section 8.1(a). Time
and Materials Charges shall be set forth in separate invoices from invoices for
the Target Price Work.  In addition, cost
and schedule performance shall be evaluated on a monthly basis, the results of which shall be provided to

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-34-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Owner, and corrective actions shall be
developed to remedy deficiencies identified by this review.

 

8.2                                 Milestone Payments.  Contractor shall be paid for the portion of the
Contract Price constituting the [**] in accordance with the Milestone Payment
Schedule in Exhibit F-1. The applicable portion of the [**] shall
be invoiced by Contractor upon the completion (or substantial completion as
provided below) of each Milestone. Invoices for Milestone Payments for Major
Equipment shall be issued separately from invoices for other Milestone
Payments.  [**]  Submittal of each invoice by Contractor for a
Milestone Payment shall constitute a representation by Contractor that it has
performed and provided the Work required for such payment in accordance with
this Agreement or otherwise covered by such invoice. Payment shall be due from
Owner within [**], in each case, following receipt of the invoice.  [**]xxxx

 

8.3                                 Final Payment. 
Upon achievement of Final Completion for each Unit, Contractor shall
submit to Owner an invoice for the final Milestone Payment for such Unit and
other payments due under this Agreement (the “Final Payment Invoice”) which shall
set forth the remaining amounts due to Contractor pursuant to this Agreement
(minus any amounts that are still being held for Final Completion Punch List
items for such Unit that cannot be completed until the next Nuclear Fuel
re-load, as provided in Section 12.5). 
Payment of the Final Payment Invoice shall be due from Owner within [**]
of its submission to Owner.  When
submitting the Final Payment Invoice for a Unit, Contractor shall: (i) submit
a written discharge, in form and substance reasonably satisfactory to both
Parties, confirming that the total of the

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-35-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Final Payment Invoice (minus any such Final Completion
Punch List items) represents full and final settlement of the monies due to
Contractor for the performance of the Work under this Agreement with respect to
such Unit, (ii) include a waiver against any mechanic’s and materialman’s
liens; provided that the waiver shall be conditioned on Contractor receiving
payment pursuant to the Final Payment Invoice and (iii) with the Final
Payment Invoice for the Second Unit, return all Sales Tax exemption
certificates issued to Contractor and Subcontractors to Owner or provide a
statement that all such certificates have been destroyed or have expired.

 

8.4                                 Supporting Documentation; Payment
Disputes.

 

(a)                                  Contractor shall submit invoices in a
format agreed to by Owner. Contractor shall make available such documentation
and materials as Owner may reasonably require substantiating Contractor’s right
to payment of any invoice. If any invoice is deficient in any material respect,
Contractor may be required by Owner to resubmit that invoice in proper form;
provided, however, that Owner shall pay any portion of it that is not deficient
or subject to dispute.  Owner shall
review each invoice and shall make exceptions, if any, by providing Contractor
with written notice by the earlier of (i) such date the invoice is paid by
Owner or (ii) [**] after Owner receives the invoice along with evidence
which reasonably documents the contractual basis of such exceptions. If Owner
provides no exceptions within such time, Owner shall pay Contractor within the
time specified for payment above.

 

(b)                                 Payment shall not waive Owner’s right to
dispute an invoice.  Any amount of an
invoice that Owner disputes shall be resolved in accordance with Article 27.

 

(i)                                     Should such dispute not be
settled within [**] of the due date, Owner shall pay [**].

 

(ii)                                  Once the dispute is resolved, Owner shall pay
any additional amount due or Contractor shall refund any amount by which it was
overpaid, as applicable, within [**] after the date of the final resolution[**].

 

(c)                                  If for any reason Owner fails to pay Contractor for all
undisputed sums due and owing by the due date or, for disputed amounts, by the
date required as set forth in (b)(i) above, Contractor shall notify Owner
of the overdue payment, and a late payment charge shall accrue
at a rate equal to [**] per annum. If Owner
fails to make payment of any undisputed amount due within [**] following the
due date or fails to make payment of any disputed amount within [**] following
the date set forth in (b)(i) above, Contractor shall provide a second
notice to Owner in writing.  If Owner
fails to make payment of the undisputed amount due within [**] following its
receipt of this second notice, Contractor has the right to suspend
performance of the Work as if Owner had ordered a suspension in accordance with
Section 22.1.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-36-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

(d)                                 Owner may take advantage of any discount
identified in Contractor’s invoice for prompt payment.

 

8.5                                 No Acceptance by Payment. 
Owner’s payment of any invoice does not constitute approval or
acceptance of any item or cost in that invoice nor shall Owner’s payment be
construed to relieve Contractor of any of its obligations under this Agreement.

 

8.6                                 Security for Payment and Performance.

 

(a)                                  Simultaneously with the execution of this Agreement, (i) Westinghouse
agrees to supply to Owner a parent company guaranty from Toshiba in the form
set forth as Exhibit I-1 and (ii) Stone & Webster
agrees to supply to Owner a parent company guaranty from Shaw in the form set forth as Exhibit I-2.

 

(b)                                 [**]

 

(c)                                  [**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-37-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

[**]

 

(d)           [**]

 

8.7                                 Separate Payments for Consortium Members. 
Each Contractor invoice shall designate the amount of the payment due to
each Consortium Member. Owner shall make payment to each Consortium Member as
indicated.

 

ARTICLE 9 — CHANGES IN THE WORK

 

9.1                                 Entitlement to Change Order. 
The following, to the extent that they impact the obligations of
Contractor under this Agreement (each, a “Change”), shall entitle Contractor to
a Change Order in accordance with the provisions of this Article 9:

 

(a)                                  any addition to, deletion from, or
modification of the Facility or any change in the Work, that is agreed by the
Parties or that arises as a result of the issuance of the COL;

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-38-

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject
  to Restricted Procedures

  

 

(b)                                 an Uncontrollable Circumstance;

 

(c)                                  a Change in Law;

 

(d)                                 issuance of new ITAAC or revisions to
ITAAC in existence as of the Effective Date;

 

(e)                                  Contractor encountering conditions at or
affecting the Site not made known to Contractor or are not evident or readily
discernible upon Contractor’s inspection of the Site as provided in Section 3.6(d) and/or
encountering Hazardous Materials for which it is not responsible;

 

(f)                                    the circumstances that entitle Contractor
to a Change Order as provided for in Section 5.6;

 

(g)                                 uncovering of the Work (unless the Work
is found to be deficient) as provided for in Section 5.7(d);

 

(h)                                 any breach of this Agreement by Owner of
its obligations under this Agreement (including, without limitation, the
obligations under Section 3.6) or delay or other demonstrable adverse
impact on Contractor’s or a Subcontractor’s activities under this Agreement
resulting from delay by Owner in giving any required approvals or in performing
any of Owner’s responsibilities under Section 3.6 (other than any delay
for which Contractor is responsible) or interference by Owner or Owner’s
Personnel or Invitees (other than Contractor or its Subcontractors or their
Personnel or Invitees);

 

(i)                                     suspension of the Work pursuant to Article 22
except to the extent that it arises as a result of Contractor’s act, omission
or default;

 

(j)                                     failure of Owner to issue the Full Notice
to Proceed or Limited Notices to Proceed in time to support Contractor’s
required activities to maintain the Project Schedule as further described in Section 3.3;

 

(k)                                  an instruction by Owner to Contractor to
accelerate the performance of the Work accepted by Contractor; or

 

(l)                                     any other event or circumstance
specifically identified in this Agreement as constituting a Change or entitling
Contractor to a Change Order.

 

9.2                                 Owner-Directed Changes. 
It is the intent of the Parties to preserve the design of the Standard
Plant, including the approach to the supply chain, construction, licensing,
operation and maintenance. However, Owner may request any Change, provided it
is technically feasible, with the understanding that such Change may cause the
Facility to no longer qualify as a Standard Plant, subject again to Sections
9.3 through 9.5.

 

9.3                                 Effect of Changes. 
To the extent that a Change adversely affects Contractor’s or its
Subcontractors’ ability to perform the Work, increases the costs for the Work,
affects

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-39-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Contractor’s ability to achieve the Net Unit
Electrical Output Guarantee or Warranties or its other obligations under this
Agreement, or causes a delay in the Project Schedule, Contractor shall be
entitled to an equitable adjustment as appropriate to the Contract Price, the
Project Schedule, the Milestone Payment Schedule, the Guaranteed Substantial
Completion Dates, the Scope of Work and/or such other parts of this Agreement
as may be affected by such Change. 
Similarly, to the extent that a Change enhances Contractor’s or its
Subcontractors’ ability to perform the Work, reduces the cost of the Work or
its other obligations under this Agreement, or shortens the Project Schedule,
Owner shall be entitled to an equitable adjustment as appropriate to the Contract
Price, the Project Schedule, the Milestone Payment Schedule, the Guaranteed
Substantial Completion Dates, the Scope of Work and/or such other parts of this
Agreement as may be affected by such Change. Any increase or decrease in the
Contract Price resulting from a Change shall be determined and shall be payable
as follows:

 

(i)                                     by [**] in an amount
proposed by Contractor and accepted by Owner (to be payable as the Parties may
agree); or

 

(ii)                                  if Owner does not accept the
[**] amount proposed by Contractor, on a Time and Materials Basis, using the
rates in Exhibit G, provided that for any such Change, Contractor
shall have the right to make a Claim for the costs of Work affected by the
Change that are not covered in the Time and Materials Charges for the Change.
Such additional costs shall be subject to audit in accordance with the terms of
Section 25.4.

 

9.4                                 Change Orders. 
Contractor shall submit written notice of a Change to Owner as soon as
reasonably practicable under the circumstances after becoming aware of the
Change. Such notice shall include (or where not possible, be followed by)
notice of the following as such information becomes available:

 

(a)                                  details of the effect of the Change on
the provisions of the Agreement;

 

(b)                                 options to mitigate the costs or delays
or enhance the savings associated with the Change;

 

(c)                                  an evaluation of the impact on the
Licensing Basis as of the date of the Change;

 

(d)                                 a written proposal for executing the Work
insofar as it has changed; and

 

(e)                                  changes that are needed to the Milestone
Payment Schedule so that it reflects the changes to the Project Schedule.

 

Change Orders shall be agreed to in writing by the
Parties.  Each Change Order shall show
the adjustments agreed to by the Parties. 
If Owner requests a proposal for a Change in the Work from Contractor or
should Contractor submit a notice for a Change under Section 9.1, a Change
Order shall be issued to reimburse Contractor for any charges incurred, or to
compensate Owner for any resulting savings, including but not limited to
charges for or savings in estimating services, design services or preparation
of proposed revisions to the Agreement. Any changed

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-40-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Work performed by Contractor prior to the execution of
a Change Order shall be at Contractor’s risk.

 

9.5                                 Disputes over Changes. 
In the event the Parties are unable to agree on any aspect of a Change
Order, the dispute shall be resolved in accordance with the provisions of Article 27.

 

9.6                                 Changes for Contractor’s Convenience.

 

(a)                                  Contractor shall have the right to take
any action at its own expense that is generally consistent with this Agreement
and that is reasonably necessary to meet the requirements of this Agreement,
including performing its obligations in accordance with Good Industry
Practices.  With respect to Equipment or
materials or aspects of the Work that are part of the Standard Plant,
Contractor shall have the right to make substitutions of Equipment or materials
set out in the Specifications, or deletions from or modifications to the
Facility or the Work as described in the Scope of Work or the Licensing Basis,
so long as such substitutions, deletions or modifications are equivalent or
better as to function and reliability on a life cycle basis and do not cause
the Equipment or materials or aspects of the Work to no longer conform to the
Standard Plant. Contractor shall provide notice of and the rationale for any
such Change to Owner.

 

(b)                                 In the event that Contractor desires to
make substitutions of Equipment or materials set out in the Specifications, or
deletions from or modifications to the Facility or the Work as described in the
Scope of Work or the Licensing Basis and such action (i) would cause the
Equipment or materials or such aspect of the Work (following the finalization
of the design of the applicable system, component or structure) to no longer
conform to the Standard Plant, or (ii) would be contrary to the COL or the
DCD, [**].

 

(c)                                  [**]

 

(d)                                 Owner’s prior written approval shall not
be required for a Field Change that is made in accordance with Contractor’s
PQAP.

 

(e)                                  Contractor shall provide its design
change and configuration control procedure(s) to Owner for its review and
comment.

 

(f)                                    [**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-41-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

9.7                                 Optional Services and Equipment. 
The Parties acknowledge and agree that Exhibit A sets forth
certain additional Services and Equipment, one or more of which, at the option
of Owner, shall be included in the Work. 
If Owner desires to exercise such option, it shall provide Contractor
written notice thereof, in which case such item shall be included in the Work
[**].

 

9.8                                 Changes in Import Fees and Duties.  In the event that there is a Change in Law after the
Effective Date that results in a reduction of the import fees or duties on the
Equipment to be paid by Contractor, [**].

 

ARTICLE 10 — UNCONTROLLABLE CIRCUMSTANCES

 

10.1                           Performance Excused. 
No Party shall be considered to be in default or in breach of its
obligations under this Agreement to the extent that performance of such
obligations is prevented, impacted or delayed by any Uncontrollable
Circumstance which arises.  Amounts due
and payable for Work performed shall not be excused due to an Uncontrollable
Circumstance. Without limiting Contractor’s right to seek a Change Order, to
the extent the Work is affected by an Uncontrollable Circumstance, Contractor
shall work diligently to cure, remove, otherwise correct, minimize and contain
costs and expenses attendant on or arising from each Uncontrollable
Circumstance.  [**]  Contractor shall provide information to Owner
to explain its determination of the manner in which the Uncontrollable
Circumstance has affected Owner [**].

 

10.2                           Notice.  If a Party’s
performance of its obligations under this Agreement is prevented, impacted or
delayed by an Uncontrollable Circumstance, then it shall notify the other Party
of the obligations, the performance of which is prevented, impacted or delayed,
and the nature and cause of the event in writing within [**] after the
notifying Party or its Project Director becomes aware of the Uncontrollable
Circumstance.  The Party affected by an
Uncontrollable Circumstance shall provide the other Party with weekly updates (i) estimating
its expected duration, the cost of any remedial action, and the probable impact
on the performance of its obligations hereunder, (ii) of the actions taken
to remove or overcome the Uncontrollable Circumstance and (iii) of the
efforts taken to mitigate or limit damages to the other Party.  The Party affected by an Uncontrollable
Circumstance shall also provide written notice to the other Party when it
ceases to be so affected.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-42-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

ARTICLE 11 — TESTING

 

11.1                           Scope and Objective of Testing.

 

(a)                                  The scope of testing associated with this
Article covers that testing which takes place for each Unit at the
Site.  The testing that shall be
performed on-Site consists of Construction and Installation Tests,
Preoperational Tests, Startup Tests and the Performance Test, each as described
in this Article 11.  Contractor
shall provide on a [**] the assistance to Owner during the Preoperational
Tests, the Startup Tests and the Performance Test (including without limitation
Technical Support) required hereunder.

 

(b)                                 The “Joint Test Working Group” consists
of an organizational group of representative personnel from each Party
performing testing services, technical supervision and/or field support working
with Owner’s operating organization.  The
Joint Test Working Group shall oversee the implementation of the Preoperational
Tests program and the Startup Tests program, including planning, scheduling and
performance of all Preoperational Tests and Startup Tests.  Owner shall delegate to Contractor the
implementation and direction of the Joint Test Working Group. Contractor shall
have overall responsibility and authority for technical direction of the
initial test program, consisting of the Construction and Installation Tests,
and Preoperational Tests for conducting those tests in accordance with the
Project Schedule, and will act as the chairman of the Joint Test Working
Group.  Upon Unit Mechanical Completion,
the Joint Test Working Group chairman will continue to have overall
responsibility and authority for the technical direction of the Start-up Test
program, but operation and control of the Unit shall reside entirely with
Owner.  Owner shall be responsible for
conducting the Startup Tests and the Performance Tests in accordance with the
Project Schedule and any delay in performance of the tests not due to the fault
of Contractor or its Personnel shall entitle Contractor to a Change Order
pursuant to Article 9.  The Joint
Test Working Group shall review and evaluate Construction and Installation
Tests, Preoperational Tests and Startup Tests results and test turnover
packages and recommend acceptance of the Turnover to Owner.  Owner is responsible for a startup
administrative manual and administrative procedures
that provide detailed requirements and govern the execution of activities
associated with the conduct of the test program, including the organization,
structure and functional relationships of the Joint Test Working Group and the
startup organization.  The startup
administrative manual shall provide direction for interface control of the
internal and external transfer of information, design data, test results and
other documents from one organization to another and the Turnover of systems
and Equipment from Contractor to Owner. 
The startup administrative manual shall
be prepared by Contractor for Owner on a [**].

 

11.2                           Construction and Installation Tests.

 

(a)                                  The
adequacy of construction and installation of components and systems shall be
verified by construction inspection and installation tests.  During the construction period, Contractor
erects the structure, installs plant equipment and performs construction
verification and inspection tests.  All
of these activities are executed, controlled, and documented in accordance with
Contractor’s approved procedures.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-43-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

During construction, Contractor completes the
Construction and Installation Test program in which various electrical and
mechanical tests are performed including but not limited to the following:

 

·                                          Cleaning and flushing

 

·                                          Hydrostatic testing

 

·                                          Checks of electrical wiring

 

·                                          Valve testing

 

·                                          Energization and operation of equipment

 

·                                          Calibration of instrumentation

 

(b)                                 During construction, Contractor completes
the building of components associated with the various systems.  The associated piping, wiring, equipment, and
controls are verified to be installed in accordance with approved final design
drawings. Construction and Installation Tests are performed and all appropriate
documentation and exceptions to construction verification or tests, or
incomplete tests shall be recorded as Turnover exceptions.  On a system basis, completion of this program
demonstrates that the system is ready for preoperational testing. The system
shall be turned over to the Joint Test Working Group.

 

11.3                           Preoperational System Tests.  Following the Construction and Installation Tests of the
particular components and systems, the preoperational system tests are conducted.  Activities during the Preoperational Tests
are conducted in accordance with a Startup Administrative Manual as provided in
the Project Execution Plan.  Initially,
the Joint Test Working Group prepares the system/components for dynamic
testing.  Systems are flushed, tuned, and
prepared for preoperational and acceptance testing.  The Joint Test Working Group, while
coordinating any remaining functional testing, shall typically direct Owner’s
operations personnel in the initial starting and operation of the various
systems.

 

(a)                                  Preoperational Tests shall be performed
to demonstrate that the components and systems perform in accordance with
selected design requirements so that initial Nuclear Fuel loading, initial
criticality, and subsequent power operation can be safely undertaken in
accordance with Law and applicable Government Approvals. Preoperational Tests
at elevated pressure and temperature are referred to as hot functional tests.
Contractor shall provide [**] advance notice to Owner of the scheduled testing
dates via updates to the Project Schedule.

 

The general objectives of the Preoperational Test
program are the following:

 

·                                          Demonstrate that essential plant
components and systems, including alarms and indications, meet appropriate
requirements based on the design.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-44-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

·                                          Provide documentation of the performance
and condition of the components and systems.

 

·                                          Provide baseline test and operating data on equipment
and systems for future use and reference.

 

·                                          Operate Equipment for a sufficient period to
demonstrate performance in accordance with the Preoperational Test procedures.

 

·                                          Demonstrate that the systems operate on an integrated
basis.

 

Abstracts for the Preoperational Tests for portions of
systems/components that perform safety-related functions; perform
defense-in-depth functions; contain, transport, or isolate radioactive
material; and for other applicable systems are specified in Chapter 14 of the
Design Control Document.

 

(b)                                 Contractor shall develop the
Preoperational Test procedures consistent with its procedures for the Standard
Plant and shall provide the Preoperational Test procedures to Owner in advance
of the testing. A team referred to as the “Preoperational Test Group” shall be
established by the Joint Test Working Group and be manned by each Party’s
personnel as mutually agreed by the Parties. 
The Preoperational Test Group shall consist of engineering test leads
and test personnel.  The Preoperational
Test Group is responsible for conducting the Preoperational Tests in accordance
with the Project Schedule.

 

(c)                                  Facility equipment used in the
performance of Preoperational Tests shall be operated by Owner in accordance
with appropriate operating procedures, thereby giving Owner’s operating staff
an opportunity to gain experience in using these procedures and demonstrating
their adequacy prior to plant initial criticality.

 

(d)                                 Contractor shall review the results of
the Preoperational Tests with the Preoperational Test Group and notify Owner
when it may proceed with the Startup Test program.

 

11.4                           Startup Tests Objectives and Protocol.

 

(a)                                  The Startup Test program begins with
initial Nuclear Fuel loading after the Preoperational Tests necessary for
Nuclear Fuel loading have been successfully completed.  Startup Tests can be grouped into four broad
categories:

 

·                                          Tests related to initial Nuclear Fuel loading.

 

·                                          Tests performed after initial Nuclear Fuel loading but
prior to initial criticality.

 

·                                          Tests related to initial criticality and those
performed at low power (less than five percent (5%)).

 

·                                          Tests performed at power levels greater than five
percent (5%)

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-45-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

During performance
of the Startup Test program, Owner’s operating staff shall have the opportunity
to obtain practical experience in the use of appropriate operating procedures
while a Unit progresses through heatup, criticality, and power operations.

 

(b)                                 The general objectives of the Startup
Test program are to:

 

·                                          Install the Nuclear Fuel in the Unit reactor vessel in
a controlled and safe manner.

 

·                                          Verify that the Unit reactor core and components,
equipment, and systems required for control and shutdown have been assembled
according to design and meet specified performance requirements.

 

·                                          Achieve initial criticality and operation at power in
a controlled and safe manner.

 

·                                          Verify that the operating characteristics of the Unit
reactor core and associated control and protection equipment are consistent
with design requirements and accident analysis assumptions.

 

·                                          Obtain the required data and calibrate equipment used
to control and protect the Facility.

 

·                                          Verify that the Unit responds to the transient tests
as described in the Design Control Document.

 

·                                          Verify the operating characteristics of the Unit
secondary plant equipment (turbine, generator, isophase bus duct and main power
transformer, heater balance, main steam, extraction steam, steam dump,
condenser, condensate, feedwater, make-up water, cooling tower, main feedwater
pumps, etc.) and associated control equipment.

 

Abstracts of the Startup Tests are provided in Chapter
14 of the Design Control Document. Contractor shall develop the Startup Test
procedures per the guidelines documented in Chapter 14 of the Design Control
Document, in accordance with its procedures for the Standard Plant and shall
provide the Startup Test procedures to Owner in advance of the testing. A team
referred to as the “Startup Test Group” shall be established by the Joint Test
Working Group and be manned by each Party’s personnel as mutually agreed by the
Parties.  The Startup Test Group shall
consist of engineering test leads and test personnel.  The Startup Test Group is responsible for
conducting the Startup Tests in accordance with the agreed upon Project
Schedule.  Contractor shall provide
Technical Support to Owner during these tests.

 

(c)                                  Contractor shall give notice to Owner of
the date (the “Ready for Startup Test Date”) when the Unit is ready, or would
have been ready [**] except for a delay caused by Owner or its Personnel or
resulting from an Uncontrollable Circumstance, for the Startup Tests on such
Unit to begin; provided, however, that such notice shall not be given until the
Construction and Installation Tests are completed and the

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-46-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Preoperational
Tests are underway such that the Unit will be ready for Startup Tests within
ninety (90) Days from such notice.

 

(i)                                     In the event of any such delay, the provisions of Article 9
shall apply.  If the Work is suspended as
a result of the delay, the Parties shall determine
as part of the Change Order process such matters as (A) maintenance
procedures for the Unit to be followed by Owner until the Startup Test can
occur, (B) whether or not Contractor should demobilize its forces for the
duration of the suspension, (C) if demobilization is to occur, Contractor
Personnel that shall either remain on the Site and/or be permitted to examine
the Unit and Owner’s maintenance records on a routine basis to determine
whether the agreed maintenance procedures are being followed and (D) validation
procedures to be undertaken on the Unit to re-determine its readiness for the
Startup Test prior to conducting the Startup Test.

 

(ii)                                  To the extent that a delay
caused by Owner or its Personnel or resulting from an Uncontrollable
Circumstance delays any Startup Test by more than [**] from the Ready for
Startup Test Date, Contractor shall be entitled to the Milestone Payments that
would be due upon or prior to Startup Test Completion, minus the direct costs
attributable to the Technical Support to have been provided by Contractor for
such Startup Test(s).

 

(iii)                               At such time as Owner is
ready for the Startup Test to be conducted, Contractor shall (if applicable)
re-mobilize at the Site on a mutually agreed date and shall proceed to provide
the Technical Support required for the Startup Test, followed by the
Performance Test and the other activities required to achieve Substantial
Completion and Final Completion. Prior to initiating the Startup Test,
Contractor shall have the right, pursuant to the agreed validation procedures
determined as described in clause (i) above, to determine whether any
degradation of the Unit has occurred. If degradation of the Unit has occurred,
Contractor shall be entitled to a Change Order pursuant to Article 9 for
the costs and time required to perform corrections to the Unit to return it to
a state ready for the Startup Test.

 

(iv)                              If the delay caused by Owner or its Personnel or resulting from an
Uncontrollable Circumstance delays any Startup Test by
more than [**] from the Ready for Startup Test Date, then (x) the Startup
Test shall be deemed to have been completed and Substantial Completion shall be
deemed to have occurred for purposes of the Warranties, Section 22.2 and
any other provisions of the Agreement pertaining to the Guaranteed Substantial
Completion Date; (y) Contractor shall be entitled to the remaining
Milestone Payments; and (z) Final Completion shall be deemed to have
occurred provided that Contractor completes such other Work that can be
completed notwithstanding the inability to conduct the Startup Test and
Performance Test. At such time, if any, as Owner is ready for the Startup Test
to be conducted, Contractor’s sole responsibility hereunder with respect to
such Startup Test shall be to provide Technical Support for the testing on a
Time and Materials Basis.

 

11.5                           Performance Tests.

 

(a)                                  Contractor shall develop the Performance
Test procedures consistent with its procedures for the Standard Plant and shall
provide the Performance Test procedures to Owner six (6) months in advance
of the testing for review.  Performance
Test procedures must

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-47-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

be
approved by Owner, such approval not to be unreasonably withheld. Owner shall
provide all consumables, semi-skilled and skilled labor, fully trained and
licensed operators and any other material or services required for the
tests.  Contractor shall maintain a
minimal construction staff and labor on Site to support the testing process.

 

(b)                                 A test (the “Net Unit Electrical Output
Test”) shall be run to determine whether the Unit meets the Net Unit Electrical
Output Guarantee.  The Net Unit
Electrical Output Test for the Unit shall be conducted in general compliance
with Power Test Code 46 (PTC-46) with the NSSS power no less than [**] of rated
power measured using the Secondary Calorimetric Methodology and for the periods
and duration discussed below.  The test
shall consist of [**] in duration.  If
upon evaluation of the data more than [**] of the test runs are found
unacceptable for reasons of equipment failure or environmental instability,
additional runs will be made.  Test run
duration may be extended if necessary to reduce the random uncertainty in the
test results to less than [**].  Data
collected within each test run will be averaged and the results corrected to
guarantee reference conditions.  The
final Net Unit Electrical Output shall be the average of the corrected net
electrical output for all of the successful test runs.

 

Corrections shall be applied to the measured net
electrical output for NSSS power, electrical power factor at the high side of
the main step-up transformer, ambient wet and dry bulb temperature and
temperature of the makeup water to the cooling tower.

 

The Net Unit Electrical Output Test for the Unit shall
be determined during a period of continuous operation of [**]. Such Net Unit
Electric Output Test shall be satisfactorily completed when the Unit has
demonstrated its capability of meeting the Net Unit Electrical Output Guarantee
as described above. The measurement frequency shall be in compliance with
PTC-46 throughout the test.

 

(c)                                  Contractor shall give notice to Owner of
the date (the “Ready for Performance Test Date”) when the Unit is ready, or
would have been ready [**] except for a delay caused by Owner or its Personnel
or resulting from an Uncontrollable Circumstance, for the Performance Test on
such Unit to begin; provided, however, that such notice shall not be given
until the Construction and Installation Tests and the Preoperational Tests are
completed and the Startup Tests are underway and would be completed within [**]
unless there has been a delay as described in Section 11.4(c).  In the event that there has been a delay in
conducting the Startup Test due to a delay caused by Owner or its Personnel or
resulting from an Uncontrollable Circumstance, then the Ready for Performance
Test Date shall be [**] after the Ready for Startup Test Date [**].

 

(i)                                     In the event of any such delay, the provisions of Article 9
shall apply.  If the Work is suspended as
a result of the delay, the Parties shall determine
as part of the Change Order process such matters as (A) maintenance
procedures for the Unit to be followed by Owner until the Performance Test can
occur, (B) whether or not Contractor should

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-48-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

demobilize its forces for
the duration of the suspension, (C) if demobilization is to occur,
Contractor Personnel that shall either remain on the Site and/or be permitted
to examine the Unit and Owner’s maintenance records on a routine basis to
determine whether the agreed maintenance procedures are being followed and (D) validation
procedures to be undertaken on the Unit to re-determine its readiness for the
Performance Test prior to conducting the Performance Test.

 

(ii)                                  To the extent that a delay
caused by Owner or its Personnel or resulting from an Uncontrollable
Circumstance delays any Performance Test by more than [**] from the Ready for
Performance Test Date, Contractor shall be entitled to the Milestone Payment
that would be due upon Substantial Completion, minus the direct costs
attributable to the Technical Support to have been provided by Contractor for
such Performance Test.

 

(iii)                               At such time as Owner is
ready for the Performance Test to be conducted, Contractor shall (if
applicable) re-mobilize at the Site on a mutually agreed date and shall proceed
to conduct the Performance Test, followed by the other activities required to
achieve Substantial Completion and Final Completion of the Unit. Prior to
initiating the Performance Test, Contractor shall have the right, pursuant to
the agreed validation procedures determined as described in clause (i) above,
to determine whether any degradation of the Unit has occurred. If degradation
of the Unit has occurred, Contractor shall (without duplication of Changes to
which Contractor is entitled under Section 11.4(c)(iii)) be entitled to a
Change Order pursuant to Article 9 for the costs and time required to
perform corrections to the Unit to return it to a state ready for the
Performance Test.

 

(iv)                              If the delay caused by Owner or its Personnel or resulting from an
Uncontrollable Circumstance delays the Performance Test
by more than [**] from the Ready for Performance Test Date, then (x) the
Performance Test shall be deemed to have been completed and Substantial
Completion shall be deemed to have occurred for purposes of the Warranties, Section 22.2
and any other provisions of the Agreement pertaining to the Guaranteed
Substantial Completion Date and the Net Unit Electrical Output Guarantee; (y) Contractor
shall be entitled to the remaining Milestone Payments; and (z) Final
Completion will be deemed to have occurred provided that Contractor completes
such other Work that can be completed notwithstanding the inability to conduct
the Performance Test. At such time, if any, as Owner is ready for the
Performance Test to be conducted, Contractor’s sole responsibility hereunder
with respect to such Performance Test and the Net Unit Electrical Output
Guarantee shall be to provide Technical Support for the testing on a Time and
Materials Basis.

 

(v)                                 Except as provided in Section 11.5(c)(iv),
should a Unit when tested be assessed to have not fully met the Net Unit
Electrical Output Guarantee, Contractor shall proceed as provided below in Section 11.6.
Contractor shall promptly notify Owner of the Unit’s readiness for any required
retest, specifying the time and date of such test, such date being not less
than seven (7) Days from the date of notification.

 

11.6                           Net Unit Electrical Output Guarantee. 
Subject to the limits of liability set forth in Section 13.2, and
subject to the provisions of this Agreement and in accordance with the
Operating Procedures and Maintenance Procedures and Facility Manuals,
Contractor guarantees

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-49-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

that the Net Unit Electrical Guarantee for a Unit,
when loaded with the Nuclear Fuel, shall be [**] (the “Net Unit Electrical
Output Guarantee”) determined using the conditions and calculation as set forth
in Exhibit L based on mechanical draft cooling towers and measured
at the high side of the main transformer including designated House Loads
pursuant to Exhibit L, as evidenced by the Net Unit Electrical
Output Test. Meeting the Net Unit Electrical Output Guarantee demonstrates that
[**].

 

(a)                                  In the event a Unit does not meet the Net
Unit Electrical Output Guarantee as of the Guaranteed Substantial Completion
Date, [**].  [**]

 

(b)                                 The Net Unit Electrical Output Guarantee
is subject to the conditions stated in Section 14.4(c) and to the
following:

 

(i)                                     Owner has provided access to
the electrical grid and sufficient electrical load to perform the test; and

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-50-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

(ii)                                  The Net Unit Electrical
Output Guarantee is based upon the conditions specified in Exhibit L.  If conditions during the test differ from
those specified, adjustments shall be made accordingly to the Net Unit
Electrical Output using graphs, tables and other data as prepared by
Contractor, after consultation with Owner, to establish the Net Unit Electrical
Output to compare to the Net Electric Output Guarantee.

 

(c)                                  Necessary auxiliary equipment for
producing the Net Unit Electrical Output shall include only the Equipment loads
provided in Exhibit L.

 

(d)                                 The Net Unit Electrical Output Guarantee
shall be demonstrated by the Net Unit Electrical Output Test to be conducted at
the times and subject to the conditions set forth herein. Satisfactory
completion of such test or re-test, or the payment of Performance Liquidated
Damages to Owner shall relieve Contractor of any further obligation with
respect to the Net Unit Electrical Output Guarantee.

 

ARTICLE 12 — STAGES OF COMPLETION

 

12.1                           Turnover.

 

(a)                                  Turnover refers to the sequential
mechanical completion of each system and structure of a Unit.  “Turnover” of a system or structure shall
occur upon the satisfaction of the following conditions:

 

(i)                                     Such system, structure or
component (A) shall be mechanically and electrically sound; (B) shall
have been cleaned out as necessary to perform the Construction and Installation
Tests for such system or structure; and (C) the subsystems comprising such
system, structure or component shall have been checked for alignment,
lubrication, and electrical continuity and hydrostatic and pneumatic pressure
integrity; and

 

(ii)                                  the Construction and Installation Tests for such
system or structure shall have been completed such that Owner can confirm that
the criteria for the Construction and Installation Tests have been met; and

 

(iii)                               Structures, systems and
components or portions thereof shall be completed, necessary coatings applied,
and the area cleaned; and

 

(iv)                              The Preoperational Test has
validated compliance with the design specifications to the extent permitted
under the Unit’s configuration status. (For example, some design requirements
cannot be validated until after Nuclear Fuel loading.)

 

(b)                                 Notice and Acceptance of Turnover. 
When Contractor believes the provisions of Section 12.1(a) have
been satisfied with respect to each system or structure, Contractor shall
deliver a written notice of such determination through the Joint Test Working
Group to Owner with sufficient detail to enable Owner to determine whether
Contractor has achieved such requirements. Turnover of such system or structure
shall be deemed to have occurred within [**] following delivery of such
determination to Owner, unless within such [**] period, Owner has notified
Contractor in writing of

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-51-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

why
it disagrees that Turnover has occurred, in which case (and without prejudice
to Contractor’s right to submit a Claim) Contractor shall take such corrective
actions as are necessary and resubmit its written notice of determination to
Owner in accordance with this Section 12.1(b).  Upon Turnover of a system or structure,
Contractor shall turn over risk of loss and care, custody, control and
operation of such system, structure or component to Owner in accordance with Section 21.2.

 

12.2                           Preoperational Test Completion.

 

(a)                                  Unit Mechanical Completion.  “Unit Mechanical Completion” shall
be achieved when the conditions as stated in Section 11.4(a) for the
commencement of Nuclear Fuel loading the Unit have been achieved.  When submitting its written notice of
determination for such Unit Mechanical Completion, Contractor shall include
notice that Turnover has occurred.

 

(b)                                 “Preoperational Test Completion” for a
Unit shall be deemed to have occurred upon satisfactory completion of the
Preoperational Tests for the Unit.

 

(c)                                  Contractor shall notify Owner when the
provisions of Section 12.2(b) have been satisfied. Owner shall accept
such Unit as having achieved Preoperational Test Completion, by delivering to
Contractor notice of that acceptance within [**] following receipt of
Contractor’s notice that Preoperational Test Completion has occurred;
alternatively, Owner may disagree that Preoperational Test Completion has
occurred by notifying Contractor in writing of why it disagrees that
Preoperational Test Completion has occurred. If no notice is issued by Owner
within the required time period, Owner shall be deemed to have accepted that
Preoperational Test Completion has occurred. The date of Preoperational Test
Completion shall be the date the Unit has achieved Preoperational Test
Completion and not the date of Owner’s acceptance.

 

12.3                           Startup Test Completion.

 

(a)                                  Prior to commencing the Startup Tests,
the Parties shall have jointly determined and agreed upon a punch list of the
remaining Work for each Unit.  The items
on the punch list that are required to be completed before the commencement of
the Startup Tests for reasons of safety or compliance with applicable Laws
shall have been completed prior to the commencement of the Startup Tests.

 

(b)                                 “Startup Test Completion” for a Unit
shall be deemed to have occurred upon satisfactory completion of the Startup
Test for the Unit or the deemed completion of a Startup Test pursuant to Section 11.4(c)(iv).

 

(c)                                  Contractor shall notify Owner when the
provisions of Section 12.3(b) have been satisfied. Owner shall accept
such Unit as having achieved Startup Test Completion, by delivering to
Contractor notice of that acceptance within [**] following receipt of
Contractor’s notice that Startup Test Completion has occurred; alternatively,
Owner may disagree that Startup Test Completion has occurred by notifying
Contractor in writing of why it disagrees that Startup Test Completion has
occurred. If no notice is issued by Owner within the required time period,
Owner shall be deemed to have accepted that Startup Test Completion has

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-52-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

occurred.
The date of Startup Test Completion shall be the date the Unit has achieved
Startup Test Completion and not the date of Owner’s acceptance.

 

12.4                           Substantial Completion.

 

(a)                                  “Substantial Completion” for a Unit shall
have occurred upon satisfactory completion of a Performance Test, the deemed
completion of a Performance Test pursuant to Section 11.5(c)(iv), or the
payment of applicable Performance Liquidated Damages by Contractor.

 

(b)                                 Contractor shall notify Owner when the
provisions of Section 12.4(a) have been satisfied. Owner shall accept
such Unit as having achieved Substantial Completion, by delivering to
Contractor notice of that acceptance within [**] following receipt of
Contractor’s notice that Substantial Completion has occurred; alternatively,
Owner may disagree that Substantial Completion has occurred by notifying
Contractor in writing of why it disagrees that Substantial Completion has
occurred. If no notice is issued by Owner within the required time period, Owner
shall be deemed to have accepted that Substantial Completion has occurred. The
date of Substantial Completion shall be the date the Unit has achieved
Substantial Completion and not the date of Owner’s acceptance.

 

12.5                           Punch List.  Prior to Substantial Completion of a Unit,
the Parties shall jointly determine and agree upon a comprehensive list of
remaining Work, which shall be of a minor nature and not prevent commercial
operation of the Unit (the “Final Completion Punch List”).  Owner shall have the right to withhold from
the Milestone Payment due upon Substantial Completion of a Unit an amount of
money equal to [**] of the expected cost of completion of the Final Completion
Punch List, which amount shall be released to Contractor upon Final Completion
of the Unit. In the event that any items on the Final Completion Punch List
cannot be performed until the next Nuclear Fuel re-load, Final Completion of a
Unit shall be deemed to have been achieved for purposes of this Agreement
provided that Contractor agrees in writing with Owner to return to complete
such Work at the time of the next Nuclear Fuel re-load, and Owner shall have
the right to continue to retain [**] of the expected cost of completion of such
items until such Work is completed. In lieu of the retention described in this Section 12.5,
Contractor shall have the right to provide a letter of credit or a bond, in
form and substance reasonably satisfactory to Owner, for the completion of the
Final Completion Punch List, in which case the amount retained for the Final
Completion Punch List shall be released to Contractor.

 

12.6                           Final Completion.

 

(a)                                  Subject to 12.5, “Final Completion” of a
Unit shall be deemed to have occurred upon the completion of the Final
Completion Punch List and the other Work required under the Agreement with the
exception of obligations under the Warranties.

 

(b)                                 Contractor shall notify Owner when the
provisions of Section 12.6(a) have been satisfied. Owner shall accept
the Unit as having achieved Final Completion by delivering to Contractor notice
of that acceptance within [**] following receipt of Contractor’s notice that
Final Completion has occurred; alternatively, Owner may reject the Unit as
having

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-53-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

achieved Final Completion by notifying Contractor in
writing of why it disagrees that Final Completion has occurred. If no notice is
issued by Owner within the required time period, Owner shall be deemed to have
accepted that Final Completion has occurred. The date of Final Completion shall
be the date the Unit has achieved Final Completion and not the date of Owner’s
acceptance.

 

(c)                                  In the event that Contractor is unable to
achieve Final Completion within [**] following Substantial Completion of the
Second Unit (or if there is no Second Unit, the First Unit) due to the fact
that Owner limits Contractor’s access to the Facility or otherwise does not
allow Contractor to take the necessary actions to achieve Final Completion,
Final Completion shall be deemed to have occurred; provided that the foregoing
shall not apply with respect to Final Completion Punch List items that cannot
be completed until the next Nuclear Fuel re-load as provided in
Section 12.5.

 

ARTICLE
13 – LIQUIDATED DAMAGES

 

13.1                           Delay Liquidated Damages. 
The Parties agree that it would be extremely difficult and impracticable
under presently known and anticipated facts and circumstances to ascertain and fix
the actual damages Owner would incur if a Unit does not achieve Substantial
Completion by the Guaranteed Substantial Completion Date for such Unit and,
accordingly, if a Unit does not achieve Substantial Completion by such Unit’s
Guaranteed Substantial Completion Date due to Contractor’s fault, Owner’s
remedy for such delay shall be to recover from Contractor as liquidated
damages, and not as a penalty, liquidated damages (“Delay Liquidated Damages”)
as follows:

 

	
  Number of Days After

  Guaranteed Substantial

  Completion Date:

  	
   

  	
  Delay
  Liquidated Damages (per Day or

  portion thereof):

  
	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  

 

If a delay in achieving Substantial Completion of a
Unit continues beyond [**] after the Guaranteed Substantial Completion Date for
such Unit, no additional Delay Liquidated Damages shall be due. Payment of the
Delay Liquidated Damages shall be Owner’s sole and exclusive remedy for
Contractor’s failure to achieve Substantial Completion of a Unit on or before
the Guaranteed Substantial Completion Date for such Unit; [**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-54-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

[**].

 

13.2                           Performance Liquidated Damages. 
If the Unit does not meet the Net Unit Electrical Output Guarantee due
to Contractor’s fault, Owner’s remedy for such failure shall be to recover from
Contractor Performance Liquidated Damages of [**] for each whole KWe that the
Net Unit Electrical Output, as demonstrated by a Net Unit Electrical Output
Test, is below the Net Unit Electrical Output Guarantee. The Parties agree that
it would be extremely difficult and impracticable under presently known and
anticipated facts and circumstances to ascertain and fix the actual damages
Owner would incur in the event that the Unit fails to meet the Net Unit
Electrical Output Guarantee, and, accordingly Owner’s remedy for such failure
shall be to recover from Contractor as liquidated damages, and not as a
penalty, the Performance Liquidated Damages. In the event that Contractor has
paid the Performance Liquidated Damages and as of the end of the first
Operational Cycle (or the second Operational Cycle if long lead equipment or
components were involved in the remedy) has been able to achieve the Net Unit
Electrical Output Guarantee or has improved the Net Unit Electrical Output,
Contractor shall be entitled to receive a refund of all or the applicable
portion of the Performance Liquidated Damages paid, based on the difference
between the Performance Liquidated Damages paid and the Performance Liquidated
Damages due following Contractor’s repair, replacement, adjustment or
modifications to the Unit as demonstrated by a Performance Test, minus
[**] per MW below the Net Unit Electrical Output Guarantee for each Day
that the Unit operated below the Net Unit Electrical Output
Guarantee.  In no event shall the total
Performance Liquidated Damages due under this Agreement exceed [**] per Unit
(the “Performance Liquidated Damages Cap”).

 

13.3                           Performance Bonus. 
Following Substantial Completion, the Net Unit Electrical Output for the
Unit will be measured when the Unit is at one hundred percent (100%) reactor
power to determine [**].  [**]

 

13.4                           Payment.  Delay
Liquidated Damages and Performance Liquidated Damages, if due for a Unit, shall
be due and payable by Contractor to Owner within thirty (30) Days following
agreement by the Parties that such amount is due. The Performance Bonus, if due
for a Unit, shall be paid within thirty (30) Days following the end of the
second Operational Cycle of such Unit.  If
the payment of any such amount is disputed, then once the dispute is resolved,
the additional amount due, if any, shall be paid, or the excess amount paid, if
any, shall be refunded, by the applicable Party, within thirty (30) Days after
the date of the final resolution, together

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-55-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

with interest at a rate equal to [**] per annum,
applied from the original due date of the payment, until paid (or in the case
of any overpayment, from the date paid until refunded by the Party).

 

ARTICLE
14 – WARRANTY

 

14.1                           Equipment.

 

(a)                                  Equipment Warranty.

 

(i)                                     Contractor warrants that the Equipment
and each Unit shall be free from defects in design, workmanship and material
and shall conform to the Specifications (the “Equipment Warranty”).

 

(ii)                                  The Equipment Warranty shall commence
upon the date  scheduled for Substantial
Completion of a Unit in the Project Schedule as of October 1, 2008 plus
the number of Days of delay caused by Contractor and shall expire on the date
that is twenty-four (24) months after that date for such Unit (the “Standard
Equipment Warranty Period”); provided, however, if Owner exercises its option
in Section 14.5 for any item of Equipment, the Warranty Period for such
item of Equipment shall be the applicable Extended Equipment Warranty Period
(as defined in Section 14.5).

 

(iii)                               [**]

 

(iv)                              The Equipment Warranty does not apply to
consumables and Equipment and material such as, but not limited to, gaskets,
seals, filters, electronic tubes, packing, fuses, transistors and light bulbs
which, by normal industry practices would be expected to be replaced during the
Standard Equipment Warranty Period.

 

(v)                                 For Equipment which is placed into
service prior to Substantial Completion, the Equipment Warranty shall commence
upon such date when an item is placed into service and shall expire on the date
that is [**] after such date.  If, however, any such item of Equipment is
placed into service prior to Substantial Completion and

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-56-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

used by Contractor to support its performance of the
Work, the Equipment Warranty shall commence upon the Substantial Completion
Date of the First Unit and shall expire on the date that is [**] after such
date.  Contractor shall give notice to Owner within [**] after such an
item has been placed into service.

 

(b)                                 Remedy.  If, for
non-conforming Equipment discovered during the applicable Warranty Period,
Owner promptly notifies Contractor, Contractor shall perform such repair or
replacement as required to meet the Equipment Warranty.  The repaired or replaced part shall be
further warranted to be free from defects in workmanship and material for a period
of [**]. The decision to repair or replace shall be made by Contractor. Removal
and reinstallation of the non-conforming Equipment shall be performed by
Contractor at its expense; provided that, Owner shall provide working access to
the Equipment (which shall include removing, disassembly, replacing and/or
reinstalling adjacent or interfering Equipment, components, materials, systems
or structures in the Unit to the extent necessary to permit Contractor to
perform its warranty obligation on the non-conforming Equipment), it being
understood that such removal, disassembly, replacing and/or reinstalling shall
not adversely affect any warranties and, at the request of Contractor, shall
furnish, without cost to Contractor, plant support personnel and facilities to
assist in the removal, reinstallation, repair and other activities occasioned
by this warranty as specified in Section 14.1(e).  Should investigation by Contractor reveal
that a defect is not covered by the Equipment Warranty, Owner agrees to reimburse
Contractor for its expenses in connection therewith.

 

(c)                                  Warranty Work Deferral. 
At Owner’s option, Warranty Work that impacts operation of the Facility
may be deferred until the time of the Unit’s next regularly scheduled
maintenance outage and the Warranty provisions hereunder shall apply
notwithstanding that such outage occurs after the end of the Standard Equipment
Warranty Period. If Contractor advises Owner that deferral of the Warranty Work
can reasonably be expected to result in damage to the Unit and/or Equipment
which occurs after Contractor’s advice and results from deferral of such
Warranty Work, Owner may elect to use the Unit and/or Equipment at its risk. In
no event may Owner defer the Warranty Work beyond [**] from the date it would
have been performed by Contractor without Owner’s deferral.

 

(d)                                 Additional Owner Obligations. 
As long as any Equipment supplied hereunder is subject to warranty,
Owner shall:

 

(i)                                     Afford Contractor an opportunity to
review Owner’s system of developing and recording data related to Facility
performance;

 

(ii)                                  Provide, without cost to Contractor, any
required decontamination to reasonable limits that shall allow Contractor to
perform its obligations under this Article 14

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-57-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

and all necessary personnel and facilities for the
removal, reinstallation, repair and other Site activities that may be
occasioned by the presence of radioactive contamination;

 

(iii)                               Provide authorized personnel of
Contractor and its Subcontractors reasonable access to the Facility should
Contractor decide to observe the manner in which the Facility is operated and
maintained;

 

(iv)                              Provide authorized personnel of
Contractor and its Subcontractors reasonable access to operation and
maintenance records of Owner; and

 

(v)                                 Afford Contractor at its expense the
opportunity to attend and be heard during the presentations to any Government
Authority relating to the Facility and Equipment performance.

 

Should Owner not provide such of the foregoing as are
required by Contractor, such action shall cause Contractor’s obligations to
terminate with respect to the particular claimed defect to the extent that
Owner’s failure caused prejudice to Contractor.

 

(e)                                  Working Access to Equipment and Plant
Support Activities to be Provided by Owner.  The plant
support personnel and facilities to be provided by Owner in accordance with
Section 14.1(b) are as follows:

 

(i)                                     operations support to establish the
required plant conditions for the repairs;

 

(ii)                                  make the plant systems, structures, and
components available and placed in the proper configuration;

 

(iii)                               provide the valve clearances and tag-outs
necessary;

 

(iv)                              provide the necessary licensed operators
in the control room and containment as required by the COL;

 

(v)                                 establish and maintain appropriate and
acceptable industrial safety conditions in accordance with Laws, Good Industry
Practices, and utility policy such that reasonably unencumbered access to the
required work areas is enabled for all personnel;

 

(vi)                              as appropriate, provide body harnesses
and/or personal flotation devices in sufficient quantities such that reasonably
unencumbered access to the required work areas is enabled for all personnel;

 

(vii)                           provide safe scaffolding meeting
applicable OSHA standards (as required);

 

(viii)                        provide suitable ambient lighting;

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-58-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

(ix)                                provide free and unobstructed access to
the Site, including maintained storage areas and roadways.  Floor conditions shall be suitable for crane
and truck operation;

 

(x)                                   provide access such as remove/reinstall
cubicle plugs and other related plant facilities, such as piping, ductwork,
cable trays, platforms, insulation, etc.;

 

(xi)                                provide logistics support and labor for
moving equipment/materials into and out of the plant and shipping;

 

(xii)                             provide lay down area(s) for
equipment storage, set-up, staging and operation.  Area requirements shall depend on the scope
of services performed;

 

(xiii)                          provide areas for storage of low specific
activity and clean equipment boxes and/or cargo containers.  The area(s) shall vary depending on
storage configurations and scope of services;

 

(xiv)                         establish and maintain appropriate and
acceptable radiological conditions in accordance with Laws, Good Industry
Practices, and utility policy such that reasonably unencumbered access to the
required work areas is enabled for all personnel;

 

(xv)                            provide anti-contamination clothing,
lockers, change area, dosimetry, health physics and radiation protection
service and badging for Site access as typically required;

 

(xvi)                         provide official whole body exposure data
for Contractor personnel upon personnel departure from the Site;

 

(xvii)                      provide Gamma isotopic analysis to
determine radioactivity of waste;

 

(xviii)                   provide breathing air and respiratory protection as
necessary;

 

(xix)                           provide plant compressed air as required;

 

(xx)                              provide air for ventilation;

 

(xxi)                           provide 110V, 220V and 480V power as
required;

 

(xxii)                        provide plant and deionized water;

 

(xxiii)                     make available to Contractor, and maintain in an
operable condition those hand tools, special tools, and calibrated equipment
necessary;

 

(xxiv)                    allow access to machine shop and welding facilities,
and hot tool crib access, as required;

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-59-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

(xxv)                       provide crane operators, including polar
crane availability on an as scheduled basis, and any other personnel necessary
to complete the tasks outside of Contractor scope;

 

(xxvi)                    provide for consumables such as wipes and rags, and
disposal of all contaminated materials;

 

(xxvii)                 provide QA/QC coverage as required in the Site
approved procedures; and

 

(xxviii)              provide outside phone lines, sanitation facilities and
drinking water.

 

(f)                                    Conditions. Such repair or replacement shall constitute complete
fulfillment of Contractor obligation under the Equipment Warranty, and upon the
expiration of the applicable Warranty Period, all such obligations shall
terminate.

 

14.2                           Services Warranty. 
Contractor warrants that the Services shall be performed by qualified
persons and using competent professional knowledge and judgment and shall
conform to Good Industry Practices and the requirements of this Agreement (the
“Services Warranty”).  If any portion of
the Services fails to comply with this Services Warranty and Owner promptly
notifies Contractor of such non-conformance along with evidence which
reasonably demonstrates Contractor’s culpability, Contractor shall promptly
re-perform the non-conforming Services [**]. The Services Warranty Period shall
be concurrent with the Standard Equipment Warranty Period (the “Services
Warranty Period”).

 

At Owner’s option, Warranty Work may be deferred until
the time of the Unit’s next regularly scheduled maintenance outage and the
Warranty provisions hereunder shall apply notwithstanding that such outage
occurs after the end of the Services Warranty Period. If Contractor advises
Owner that deferral of the Warranty Work can reasonably be expected to result
in damage to the Unit and/or Equipment which occurs after Contractor’s advice
and results from deferral of such Warranty Work, Owner may elect to use the
Unit and/or Equipment at its risk. In no event may Owner defer the Warranty
Work beyond [**] from the date it would have been performed by Contractor
without Owner’s deferral.

 

14.3                           Warranty of Title. 
Contractor represents and warrants that the Work, including the
Equipment furnished by it and its Subcontractors that become part of the
Facility or are furnished to Owner as spare parts shall be legally and
beneficially owned by Owner free from any Liens (other than Liens created by
the actions of Owner, including non-payment). In the event of any nonconformity
with this warranty, Contractor, at its own expense, upon written notice of such
failure, shall indemnify, defend and hold harmless Owner from the consequences
of such defect in title and such obligations shall survive the expiration,
cancellation or termination of this Agreement.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-60-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

14.4                           Limitations and Disclaimers.

 

(a)                                  THE WARRANTIES AND GUARANTEES AND RELATED
REMEDIES SET FORTH IN THIS ARTICLE 14 ARE EXCLUSIVE AND ARE IN LIEU OF ALL
OTHER WARRANTIES AND RELATED REMEDIES WHETHER STATUTORY, EXPRESS OR IMPLIED
(INCLUDING WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE
AND WARRANTIES ARISING FROM COURSE OF DEALING OR USAGE IN TRADE) AND WHETHER
CLAIMS BY OWNER ARE BASED IN CONTRACT OR IN TORT (INCLUDING FAULT, NEGLIGENCE
OR STRICT LIABILITY).

 

(b)                                 Any warranties not expressly made herein
are expressly waived by Owner.

 

(c)                                  Notwithstanding the foregoing provisions
of this Article 14, Contractor shall have no liability hereunder for
non-conformance or failure of Equipment, or material, or performance, that
results, in whole or in part, from:

 

(i)                                     Operation of the Equipment outside of the
design basis of the Equipment or integrated system.

 

(ii)                                  Following Turnover of a system or
structure, improper use, or abnormal handling, storage, operation or
maintenance of the Equipment or material therein, or operation outside the
guidelines of the Specifications, including employment at any time for purposes
other than those for which such Equipment and material are intended, or under other
abnormal conditions or incompetent supervision.

 

(iii)                               Alteration, abuse or misuse of the
Equipment by persons other than Contractor, its Subcontractors and the
employees and agents of either.

 

(iv)                              Any operation or maintenance of the
Equipment that is not in accordance with the Unit Operating Procedures and
Maintenance Procedures.

 

(v)                                 Operation by personnel not qualified in
accordance with Section 3.6(g).

 

(d)                                 Contractor shall be relieved from
fulfilling its warranty obligations as specified in this Article 14 if:

 

(i)                                     A Nuclear Incident occurs through no
fault of Contractor and gives rise to the non-conformance, and

 

(ii)                                  All the consequences, including
radiation, of such Nuclear Incident preventing Contractor from performing such
warranty obligations are not removed within the applicable Warranty Period.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-61-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

14.5                           Extended Equipment Warranty. 
No later than [**] following issuance of the Full Notice to Proceed,
Contractor shall provide to Owner an option for extended warranties for [**].
At the time of providing the option, Contractor also shall provide information
as to the duration of such warranties, the price for such extended warranties
(which shall be developed using the same pricing methodology as the pricing for
the Equipment to which such extended warranties apply) and any special terms
applicable to such extended warranties (each, an “Extended Equipment
Warranty”). Owner shall have the right to exercise its option for any such
Extended Equipment Warranty within the time period specified for the exercise
of the option by the Equipment vendor. The terms of such Extended Equipment
Warranties shall be set forth in Exhibit W. The time period beyond
the Standard Equipment Warranty Period to which each such Extended Warranty
applies is referred to as the “Extended Equipment Warranty Period” for such
piece of Equipment.

 

14.6                           Limitation on Warranty Liability. 
Contractor’s total liability under or in connection with the liabilities
in this Article shall not exceed the amount provided in Section 17.2;
[**].

 

ARTICLE
15 – INDEMNITY

 

15.1                           Contractor Indemnity. 
Except with respect to a Nuclear Incident, Contractor shall indemnify,
defend and hold harmless Owner, its Affiliates, and their respective partners,
shareholders, officers, directors, and lenders from and against Third Party
Claims and costs and expenses associated therewith (including attorneys’ fees)
from any injury of or death to natural persons, or damage to or destruction of
third party property (i.e., property other than the Facility or other property
belonging to Owner) to the extent arising from (i) the negligent or
willful acts or omissions of Contractor or its Personnel or Invitees acting
within the scope of their employment or for which applicable Law would
otherwise hold Contractor liable for such acts or omissions, (ii) any
Liens arising from nonpayment to any Subcontractor in connection with the Work,
provided that Contractor has been paid in accordance with this Agreement, or
(iii) the release on or from the Site of any Hazardous Materials, but only
to the extent such release is due to Contractor’s or a Subcontractor’s or their
Personnel’s or Invitees’ negligence or willful misconduct while acting within
the scope of their employment or for which applicable Law would otherwise hold
Contractor liable for such acts or omissions. 
Contractor’s obligations in this Section 15.1 are limited to the
proceeds of the insurances required to be provided hereunder, provided that if
the insurance program is a Contractor controlled insurance program, the limit
shall be the amount of the proceeds from such insurance (or the proceeds which
would have been received, if Contractor had not failed to obtain such
insurance).  Contractor’s obligations in
this Section 15.1 are further conditioned upon Owner giving Contractor
prompt notice of any known claims for which it seeks indemnity hereunder (along
with documentation which reasonably evidences Contractor’s responsibility
thereof) and Owner providing such assistance and cooperation in the defense of
indemnified claims as Contractor shall reasonably request as set forth in more
detail in Section 15.5. [**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-62-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

[**]

 

15.2                           Owner’s Indemnity. 
Except with respect to a Nuclear Incident, and subject to limitations on
Santee Cooper’s obligations as a matter of South Carolina law, Owner shall
indemnify, defend and hold harmless Contractor and Contractor Interests from
and against Third Party Claims and costs and expenses associated therewith
(including attorneys’ fees) from any injury of or death to natural persons, and
damage to or destruction of third-party property (i.e., property other than
that belonging to Contractor and Contractor Interests) to the extent arising
from (i) the negligent or willful acts or omissions of Owner or its
Personnel or Invitees (other than Contractor or its Personnel or its Invitees)
acting within the scope of their employment or for which applicable Law would
otherwise hold Owner liable for such acts or omissions; and (ii) any
contamination of the environment or injury to natural resources as a result of
any Hazardous Materials on, at or under the Site to the extent such
contamination or injury occurs through the fault, negligence, willful
misconduct or strict liability of Owner or its Personnel or Invitees (other
than Contractor or Contractor’s Personnel or Invitees) acting within the scope
of their employment or for which applicable Law would otherwise hold Owner
liable for such acts or omissions. Owner obligations in this Section 15.2
are limited to the proceeds of the insurances required to be provided
hereunder, provided that if the insurance program is an OCIP, the limit shall
be the amount of the proceeds from such insurance (or the proceeds which would
have been received, if Owner had not failed to obtain such insurance). Owner’s
obligations in this Section 15.2 are further conditioned upon Contractor
giving Owner prompt notice of any claims for which it seeks indemnity hereunder
(along with documentation which reasonably evidences Owner’s responsibility
thereof) and Contractor providing such assistance and cooperation in the
defense of indemnified claims as Owner shall reasonably request as set forth in
more detail in Section 15.5.  [**]

 

15.3                           Intellectual Property Indemnity. 
Contractor shall assume at its sole option and expense, the settlement
or defense of any and all claims, demands, costs, suits, actions, proceedings,
fines and penalties (and interest thereon) brought against Owner to the extent
based on a Third Party Claim that any Facility, Unit, Work and/or Equipment
furnished by Contractor results in an infringement, or claim of infringement by
Contractor, of any patent, trademark, copyright or any other similar
intellectual property protection issued by a duly authorized Government
Authority of the United States, Canada, a European Union country, or another
country where the Equipment was manufactured in connection with the Facility, a
Unit, the Work and/or Equipment furnished by Contractor hereunder, except where
the same resulted from following directions, specifications, drawings, plans or
procedures prepared by Owner or by third parties for Owner and selected by
Owner.  If a suit is brought against
Contractor based on any Facility, Unit, Work and/or Equipment supplied by
Contractor which implements any such Owner directions, specifications, drawings
plans or procedures, Owner shall protect Contractor to the same extent that
Contractor has agreed to protect Owner hereunder.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-63-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

In the event any Facility, Unit, Work and/or Equipment
so defended is held to constitute infringement or its use is enjoined,
Contractor shall, at its own expense and option, either: (a) procure for
Owner the right to continue to use such Facility, Unit, Work and/or Equipment; (b) re-perform
the Work or replace the Facility, Unit and/or Equipment with substantially
equivalent noninfringing Facility, Unit, Work and/or Equipment; or (c) modify
the Facility, Unit, Work and/or Equipment so that it becomes noninfringing;
provided, however, that such Work re-performed and Facility, Unit and/or
Equipment replaced or modified conforms to the requirements of this Agreement.

 

THIS IS AN EXCLUSIVE STATEMENT RELATING TO
INTELLECTUAL PROPERTY RIGHTS AND ALL THE REMEDIES OF THE PARTIES RELATING
THERETO.

 

15.4                           Owner’s Nuclear Incident Indemnity.

 

(a)                                  Notwithstanding any other provision to
the contrary, Owner shall, without cost to Contractor Interests, obtain and
maintain “financial protection” and an “indemnification agreement”, for
protection against liability for Nuclear Incidents (including master worker
coverage), both in such form and amount as shall satisfy the requirements of Section 170
of the Atomic Energy Act of 1954, as amended. In the event that the nuclear
liability protection contemplated by Section 170 of the Atomic Energy Act
of 1954, as amended, is repealed, changed, or is not renewed, Owner shall
maintain in effect, to the extent available on commercially reasonable terms,
liability protections through governmental indemnity, limitation of liability
and/or insurance of comparable coverage which shall not result in a material
impairment of the protection afforded Contractor Interests by such nuclear
liability protection which is in effect as of the Effective Date, taking into
account the availability and cost of such coverage, customary practice in the
United States commercial nuclear utility industry for plants of similar size
and character of the Facility and other relevant factors in light of the then
existing conditions. To the extent available on commercially reasonable terms,
Owner shall ensure that Contractor Interests are included in the omnibus
definition of “insured” under such alternate insurance coverage or are
otherwise included as an additional insured at no cost to Contractor Interests.

 

(b)                                 Owner shall prior to the initiation of
Work at the Site and without cost to Contractor, obtain and maintain property insurance
for protection against liability for Nuclear Incident on the Facility and the
existing adjacent nuclear generation facility in a form and amount required by
the Nuclear Regulatory Commission and the current customary industry practice
from time to time, providing protection against loss or damage to the Facility
and the existing adjacent nuclear generation facility.  Such insurance shall cover Contractor
Interests, as their interests may appear. Owner hereby waives all rights of
recovery and subrogation on behalf of itself and its insurers against
Contractor Interests for any loss or damage covered by such property insurance
during the Work and thereafter, including the deductibles under any insurance
policy.

 

(c)                                  None of Contractor Interests shall be
liable to Owner or its insurers or any other party for (i) any on-Site
property (and existing nuclear facility at the V.C. Summer Station) loss or
damage due to any nuclear energy hazard, and (ii) losses or damages caused
by reason of unavailability of the nuclear power and existing adjacent nuclear
station, or by reason of

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-64-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

shutdowns of the station or other facilities or
service interruptions (including loss of profits or revenue, inventory or use
charges, cost of replacement power, cost of capital or claims by customers) or
for any other indirect, special, incidental, punitive or consequential loss,
damage or injury, whether or not based on any claim or a negligent or faulty
act or strict liability due to any nuclear energy hazard. To the extent Owner
or its insurers recover damages from a third party for damage due to the
nuclear energy hazard to which the foregoing waivers apply, Owner shall
indemnify Contractor Interests against any liability which such third party
recovers over from Contractor and/or its Subcontractors for any such loss or
damage. In the event that Contractor Interests incur any cost, loss, damage or
expense arising out of or resulting from a claim by a third party based on
Owner’s recovery of such damages, Owner shall promptly reimburse Contractor for
such cost, loss, damage or expense.  As
used in this Section 15.4, the term “nuclear energy hazard” shall mean
radioactive, toxic, explosive or other hazardous properties of “source material”,
“special nuclear material”, or “by-product material” as such terms are defined
in the Atomic Energy Act of 1954, as amended. 
Owner on behalf of itself and its insurers, hereby waives any right of
recovery and subrogation against Contractor and Contractor Interests for any
loss or damage (whether direct, indirect, consequential or otherwise) whether
or not based on any claim or a negligent or faulty act or strict liability, due
to any nuclear energy hazard, during the performance of the Work and
thereafter.

 

(d)                                 As used in this Section 15.4, the
term “on-Site property” means any property at the site of a nuclear facility as
defined in the nuclear liability policy for the Site for nuclear liability and
indemnity purposes; the term “damage” means loss, damage or loss of use; the
term “liable” or “liability” means liability of any kind at any time, whether
in contract, tort (including negligence) or otherwise.

 

(e)                                  The provisions hereof providing for
limitations of or protection against Contractor’s liability shall survive
termination of this Agreement or completion of the Work hereunder.

 

15.5                           Indemnity Procedures.

 

(a)                                  The indemnifying Party shall have the
right to conduct and control, through counsel of its own choosing, reasonably
acceptable to the indemnified Party, any Third Party Claim, provided that, upon
acceptance of the indemnity obligations hereunder, the indemnifying Party shall
waive any right to protest or challenge its indemnity obligations.  The indemnifying Party shall keep the
indemnified Party fully informed in the conduct of the proceeding.  The indemnified Party shall be entitled to
participate at its cost in any such action.

 

(b)                                 The indemnified Party may, at its
election, participate in the defense thereof at its sole cost and expense;
provided, however, that if (i) the indemnifying Party shall fail to defend
any Third Party Claim, (ii) the Parties mutually agree in writing to allow
the indemnified Party to assume the defense of such Third Party Claim and
forego any indemnity claimed under this Article, (iii) in the reasonable
opinion of legal counsel for the indemnified Party, such Third Party Claim
involves the potential imposition of a criminal liability on the indemnified
Party, its directors, officers, employees or agents, or (iv) in the
reasonable opinion of legal counsel for the indemnified Party, an actual or
potential conflict of interest exists where it is advisable for such
indemnified Party to be represented by separate counsel, then the

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-65-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

indemnified Party shall be entitled to control and
assume responsibility for the defense of such Third Party Claim, at the cost
and expense of the indemnifying Party (except in the case of (ii) above,
in which the indemnified Party agrees to forego the indemnity). The
indemnifying Party may, in any event, participate in such proceedings at its
own cost and expense.  The indemnified
Party shall not have the right to settle without the written consent of the
indemnifying Party (which consent shall not be unreasonably withheld), unless,
in the written opinion of the indemnified Party’s legal counsel, such claim is
meritorious.

 

(c)                                  The indemnifying Party, in the defense of
any such litigation, other proceeding or other claim, shall have the right in
its sole discretion to settle such Third Party Claim only if (i) settlement
involves only the payment of money and execution of appropriate releases of the
indemnified Party, (ii) there is no finding or admission of any violation
of Law or violation of the rights of the indemnified Party, and (iii) the
indemnified Party shall have no liability with respect to such compromise or
settlement. Otherwise, no such Third Party Claim shall be settled or agreed to
without the prior written consent of the indemnified Party, which shall not be
unreasonably withheld.

 

(d)                                 The indemnified Party and the
indemnifying Party (i) shall fully cooperate in good faith in connection
with such defense and shall cause their legal counsel and accountants to do the
same; (ii) shall make available to the other Party all relevant books,
records, and information (in such Party’s control) during normal business
hours; and (iii) shall furnish to each other, at the indemnifying Party’s
expense, such other assistance as the other Party may reasonably require in
connection with such defense, including making employees of the indemnified
Parties available to testify and assist others in testifying in any such
proceedings.

 

ARTICLE
16 – INSURANCE

 

16.1                           Phase I Insurance Requirements.

 

(a)                                  Except as otherwise provided hereunder,
Contractor agrees to furnish and maintain at all times during the course of the
Phase I Work to be performed hereunder, Worker’s Compensation, liability and
other insurance coverage required hereunder and in the amounts as follows:

 

(i)                                     Worker’s Compensation – Statutory.  Coverage shall include U.S. Longshoremen’s
and Harbor Workers Act coverage where applicable.  The insurance purchased pursuant to this Section 16.1(a)(i) shall
include an “All States” endorsement.

 

(ii)                                  Employer’s Liability, including an “All
States” endorsement – [**].  Coverage
shall include U.S. Longshoremen’s and Harbor Workers Act coverage where
applicable.

 

(iii)                               Commercial General Liability, (excluding
professional liability) including Contractual, Independent Contractors, -
Bodily Injury and Property Damage Combined Single Limit – [**] Each Occurrence,
[**] Aggregate, Personal Injury – [**]. 
Products and Completed Operations – [**].

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-66-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

(iv)                              Automobile Liability coverage including
owned, hired, and non-owned automotive equipment used in connection with the
insured operation - Bodily Injury and Property Damage Combined – [**] Each
Occurrence.  Owner shall provide similar
coverage for any of its owned, hired and non-owned automotive equipment.

 

(v)                                 Contractor’s Equipment Coverage – in the
amount of the value of the equipment through insurance or self insurance.

 

(vi)                              Pollution Liability on a project basis,
which includes the sudden or accidental release of any material that may be
considered a pollutant at or around the Site, as a result of the Work done by
Contractor or any tier Subcontractor – [**] Each Occurrence, [**] Aggregate.  Notwithstanding the foregoing, this coverage
shall be taken out within [**] after the Effective Date.

 

(vii)                           Open Cargo Insurance must be obtained on
materials and equipment to be transported to the Site.

 

(viii)                        Umbrella Form Excess Liability Insurance
with a coverage limit of [**].

 

(ix)                                Professional Liability on a project basis
with a coverage limit of [**]. 
Notwithstanding the foregoing, this coverage shall be taken out within
[**] after the Effective Date.

 

(b)                                 Builder’s Risk Insurance, [**] shall be
purchased by Owner at limits and coverages and other provisions as enumerated
in Section 16.2(a)(ii), naming Owner, Contractor, and Subcontractors as
additional insureds.  The liability of
Contractor for any loss or damage to any equipment or materials, Work,
completed Facility and surrounding Owner property shall be as provided in Section 16.2(a)(ii).
Should Owner decide not to procure such coverage until the commencement of
Phase II, Contractor’s liability for any loss or damage during Phase I, whether
based on contract, tort (including fault, negligence and strict liability) or
otherwise, shall not exceed [**] for any occurrence as if Owner had procured a
standard Builder’s Risk policy subject to the limitations in Section 16.2(a)(ii).  [**]  Owner
shall reimburse Contractor on a [**] to remedy such loss or damage that exceed
such amount, whether based on contract, tort (including fault, negligence and
strict liability) or otherwise.

 

16.2                           Phase II Insurance Requirements.

 

(a)                                  For Phase II, Owner shall have the option
of implementing an Owner Controlled Insurance Program (“OCIP”), as set forth in
Exhibit U. If Owner decides not to implement the OCIP, Contractor
will have the right to implement a Contractor-Controlled Insurance Program (“CCIP”),
implementing the provisions of Exhibit U.  Contractor shall be reimbursed for the CCIP
by Owner on a Time and Materials Basis. The Parties recognize that Exhibit U
is written for an OCIP, and will need to be modified accordingly if a CCIP is
to be

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-67-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

implemented. If neither an OCIP or a CCIP is
implemented, each of Owner and Contractor, as applicable, shall maintain the
coverages specified in Section 16.1, with the following exceptions, such
coverages to be reimbursed by Owner on a Time and Materials Basis:

 

(i)                                     the coverage limit for the Umbrella
Excess Liability shall be increased to [**] per occurrence and aggregate.

 

(ii)                                  Builder’s Risk Insurance, if not already
obtained, shall be obtained at limits determined appropriate by the
Parties.  Such Builder’s Risk policy
shall (A) name Contractor and all Subcontractors as additional insureds
(without having any liability for the payment of premiums); (B) cover all
risks of loss or damage to the Facility (I) during construction, and (II) if
not covered by the Open Cargo Insurance, during transportation of any materials
and equipment, and (III) during storage, (IV) during the Work, and (V) until
replaced by Owner’s Operating Property coverages, and (VI) with limits of
coverage equal to the maximum credible loss to the Facility as agreed to by the
Parties; and (C) provide coverage for resultant damage due to any error in
design, defects in equipment or material or faulty workmanship; and (D) provide
delay in start-up coverage (subject to a commercially reasonable deductible),
if available on a commercially reasonable basis.  Any recovery under the delay in start-up
coverage resulting from an event that gives rise to a covered claim under this policy
shall reduce any Delay Liquidated Damages by the same amount. Notwithstanding
any other provision to the contrary, Owner on behalf of itself and the insurer
hereby waives all rights of recovery and subrogation against Contractor and its
Subcontractors, and their Affiliates and Personnel, including any losses within
the deductibles and any excess losses; provided that Contractor shall be liable
for Owner’s deductible under its property insurance policy(ies); provided
further, and notwithstanding any other provision to the contrary, that the
liability of Contractor and Contractor Interests for any loss or damage to any
equipment, materials, Work, completed Facility and surrounding Owner property
shall be limited to claims arising to the extent of Contractor’s negligence and
shall in no event exceed [**] for any occurrence.  Contractor’s liability for the payment of
such amount shall not be reimbursable hereunder.  Owner shall reimburse Contractor on a Time
and Materials Basis to remedy such loss or damage that exceed such amount,
whether based on contract, tort (including fault, negligence and strict
liability) or otherwise[**].  [**]  The foregoing provisions are for the sole benefit
of Owner, and the Parties do not intend such provisions to be for the benefit
of any third party, including without limitation any insurer.

 

(b)                                 Regardless of whether Owner or Contractor
adopts an OCIP or CCIP, as applicable, Contractor shall be responsible for
maintaining the following insurance coverages during Phase II:

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-68-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

(i)                                     Professional Liability: Contractor shall continue to carry
Professional Liability Insurance described under Section 16.1(a)(ix).

 

(ii)                                  Pollution Liability: Contractor shall continue to carry
Pollution Liability Insurance described under Section 16.1(a)(vi) with
an increased coverage limit of [**] per occurrence and [**] in the aggregate.

 

(iii)                               Employment Practices Liability: 
Contractor shall carry Employment Practices Liability [**] with a
coverage limit of [**] per occurrence and in the aggregate.

 

16.3                           Provisions Applicable to all Coverages.

 

(a)                                  After the execution of this Agreement and
prior to the commencement of any Work, each Party shall have on file with the
other party (and in the case of Owner, Owner’s Supplier Relations Department)
the applicable insurance certificate(s). 
Such certificate(s) shall provide that thirty (30) Days written
notice be given to the other Party prior to any material change or cancellation
of the insurance.  Other than the OCIP or
CCIP, as applicable, the Builder’s Risk Insurance and Owner’s Operating
Property coverages, each Party shall name the other Party, its subsidiaries and
their successors and assigns, as additional insured (except for Worker’s
Compensation and Professional Liability and Pollution Liability coverage) for
their vicarious liability arising out of such Party’s negligent operations or
such Party shall be covered under the omnibus provisions thereof. For the OCIP
or CCIP, as applicable, and Owner’s Operating Property coverage, each Party and
Contractor Interests shall be named as an additional insured thereon, at no
cost to Contractor. All policies shall be written to include a waiver of
subrogation in favor of the other Party and its Affiliates and Contractor
Interests during the performance of the Work and thereafter.  Owner’s policies for Builder’s Risk Insurance
and other coverages obtained pursuant to the OCIP shall be subject to the
Contractor’s review and approval, which shall not be unreasonably
withheld.  [**]

 

(b)                                 All such insurance shall be with sound
insurance companies which have an AM Best Rating of A- VII as the minimum and
authorized to do business in the state where the Work is to be performed. None
of the liability policies shall have any “other insurance” clause or language
which would jeopardize the primacy of Contractor’s insurance with respect to
Owner’s self-insured retention or excess insurance.  The above Contractor requirements may be met
by both Consortium Members providing separate certificates.  Any such limits of coverages may be met in
one or more layers of coverage.

 

(c)                                  Neither a failure of a Party to provide
the required certificate of insurance nor such Party’s submission of a
certificate of insurance not in conformance with the insurance requirements
stated herein shall relieve such Party from the obligation to have in force the
required insurance coverages.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-69-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

(d)                                 Each Party is responsible for any
deductibles associated with its policies of insurance or its self-insured
retentions, except as otherwise provided hereunder.

 

(e)                                  Contractor understands that Owner may
have an administrator on-Site at all times in which Contractor or its Personnel
are at the Site.  Contractor shall
interface and cooperate with Owner’s administrator.  Additionally, Contractor shall follow any
recommendations made by the NRC, Nuclear Electric Insurance Limited (“NEIL”),
the Institute of Nuclear Power Operators (“INPO”) and American Nuclear Insurers
(“ANI”).

 

ARTICLE
17 – LIMITATION
OF LIABILITY

 

17.1                           No Consequential Damages. 
EXCEPT TO THE EXTENT THE PAYMENT OF LIQUIDATED DAMAGES COULD OTHERWISE
BE DEEMED TO BE SUCH DAMAGES, IN NO EVENT SHALL CONTRACTOR OR CONTRACTOR
INTERESTS BE LIABLE, WHETHER BASED ON CONTRACT (INCLUDING BREACH, WARRANTY,
INDEMNITY, ETC.) OR TORT (INCLUDING FAULT, NEGLIGENCE AND STRICT LIABILITY),
UNDER ANY WARRANTY OR OTHERWISE, RELATING TO OR ARISING OUT OF THE WORK OR THIS
AGREEMENT, FOR ANY CONSEQUENTIAL, INDIRECT, SPECIAL, PENAL, OR INCIDENTAL LOSS,
DAMAGE OR INJURY, INCLUDING ANY SUCH DAMAGES WHICH RESULT FROM LOSS OF USE OF
PROPERTY, EQUIPMENT OR SYSTEMS, LOSS BY REASON OF FACILITY SHUTDOWN OR SERVICE
INTERRUPTION, COSTS OF CAPITAL OR EXPENSES THEREOF, LOSS OF PROFITS OR REVENUES
OR THE LOSS OF USE THEREOF, OR COST OF PURCHASED OR REPLACEMENT POWER
(INCLUDING ADDITIONAL EXPENSES INCURRED IN USING EXISTING POWER FACILITIES) OR
FROM CLAIMS OF CUSTOMERS.

 

17.2                           Maximum Total Liability; Time Limitation. 
WITH RESPECT TO A UNIT, NOTWITHSTANDING ANY OTHER PROVISION TO THE
CONTRARY, CONTRACTOR’S AND CONTRACTOR INTERESTS’ TOTAL AGGREGATE LIABILITY
UNDER THIS AGREEMENT, ARISING OUT OF OR IN CONNECTION WITH THE WORK OR THIS
AGREEMENT, WHETHER BASED ON CONTRACT (INCLUDING BREACH, WARRANTY, INDEMNITY,
ETC.), TORT (INCLUDING FAULT, NEGLIGENCE OR STRICT LIABILITY) OR OTHERWISE,
SHALL NOT EXCEED AN AGGREGATE AMOUNT EQUAL TO [**] OF THE PAYMENTS FOR SUCH
UNIT THAT HAVE BEEN MADE TO CONTRACTOR AS OF THE DATE OF THE EVENT OR
CIRCUMSTANCE GIVING RISE TO THE CLAIM (THE “MAXIMUM LIABILITY AMOUNT”).  FOR THE PURPOSE OF DETERMINING WHETHER THE
MAXIMUM LIABILITY AMOUNT HAS BEEN MET, INSURANCE PROCEEDS RECEIVED FROM THE
INSURANCE POLICIES REQUIRED TO BE MAINTAINED UNDER THIS AGREEMENT SHALL NOT BE
INCLUDED.  [**]  IN NO EVENT MAY ANY CLAIM BY OWNER
AGAINST CONTRACTOR ARISING OUT OF OR IN CONNECTION WITH THE WORK OR THIS
AGREEMENT,

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-70-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

WHETHER BASED ON CONTRACT (INCLUDING BREACH, WARRANTY,
INDEMNITY, ETC.), TORT (INCLUDING FAULT, NEGLIGENCE OR STRICT LIABILITY) OR
OTHERWISE BE BROUGHT, WITH RESPECT TO A UNIT, MORE THAN [**] AFTER THE END OF
THE STANDARD EQUIPMENT WARRANTY PERIOD (EXCEPT FOR ANY LIABILITY ASSOCIATED
WITH BREACH OF AN EXTENDED EQUIPMENT WARRANTY, WHICH MUST BE BROUGHT NO LATER
THAN [**] AFTER THE END OF THE EXTENDED EQUIPMENT WARRANTY PERIOD APPLICABLE TO
SUCH ITEM OF EQUIPMENT).

 

17.3                           Division of Liability.

 

(a)                                  The Consortium Members agree that [**].

 

(b)                                 SCE&G and Santee Cooper agree that
they are jointly and severally liable for Owner’s obligations hereunder, to the
extent such joint and several liability does not conflict with South Carolina
Law applicable to Santee Cooper. To the extent the prior sentence conflicts
with South Carolina Law, then notwithstanding that both SCE&G and Santee
Cooper are named in this Agreement as “Owner”, as between Contractor and Owner,
SCE&G shall be solely liable for the obligations and liabilities of Owner
hereunder.

 

ARTICLE
18 – LIENS

 

18.1                           Liens.  Contractor
shall keep the Facility, the Site and the Equipment free from Liens (other than
liens arising from acts of Owner or Owner’s failure to pay amounts due to
Contractor), and shall promptly notify Owner of any known Liens filed against
the Facility, the Site, or the Equipment and any structures comprising the
Facility or located on the Site.  If
Owner seeks Contractor’s indemnification for any Lien, Owner shall:

 

(a)                                  Give Contractor prompt written notice of
any Lien of which it has knowledge; and applicable documentation regarding the
Lien;

 

(b)                                 Cooperate in the defense of litigation
relating to the Lien; and

 

(c)                                  Give Contractor sole control of the
defense and settlement, to the extent of Contractor’s liability, for the Lien
if Contractor confirms in writing an obligation to indemnify Owner with respect
to the Lien.

 

18.2                           Discharge or Bond. 
Contractor shall take prompt steps to discharge or bond any Lien filed
against the Facility, any Equipment, and any structures comprising the Facility
or located on the Site by any Subcontractor based on a claim for payment by
Contractor in connection with the Work. Contractor shall have the option of
providing an indemnity to Owner

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-71-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

in lieu of discharging or providing a bond, for up to
a [**] period to allow Contractor a reasonable time to resolve the cause of the
filing of the Lien.  If Contractor fails
to indemnify, discharge or promptly bond any Lien, Owner shall have the right,
upon notifying Contractor in writing and providing Contractor reasonable time
to indemnify, discharge or bond the Lien, to take any and all reasonable
actions and steps to satisfy, defend settle or otherwise remove the Lien at
Contractor’s expense, including reasonable attorneys’ fees, costs and
expenses.  Owner shall have the right to
recover these expenses from Contractor. 
Contractor shall have the right to contest any Lien, provided it first
provides to Owner the indemnity provided for above or it may provide the lien
holder, a court or other third Person, as applicable, a bond or other
assurances of payment necessary to remove the Lien related to the Work from the
Site and the Facility in accordance with the Laws of the State of South
Carolina.

 

ARTICLE
19 – PROPRIETARY DATA

 

19.1                           Protection of Owner Proprietary Data.

 

(a)                                  Any Proprietary Data of an Owner
disclosed to Contractor shall be marked “Proprietary” or the like on each page in
which the respective party claims a proprietary or confidential interest
therein (or for electronic data, on the opening screen of such data). If
Contractor receives information which it recognizes as being Proprietary Data,
but which has not been marked as such, it shall promptly notify Owner and mark
the information as Proprietary Data.

 

(b)                                 In the use of any Owner Proprietary Data
by Contractor for the purpose of providing required information to, and/or
securing Government Approvals from, any Government Authority, Owner and
Contractor shall cooperate to minimize the amount of such information furnished
consistent with the interests of Owner and the requirements of the Government
Authority involved.

 

(c)                                  Contractor agrees that it shall not,
during or after the term of this Agreement, disclose any Proprietary Data of
Owner and its Affiliates, which is provided to Contractor during the
performance of Work under this Agreement, including but not limited to, their
costs, charges, rates, records, operating procedures, and methods of doing
business, to any Person (other than Subcontractors as required for the
performance of the Work), or to the general public for any reason or purpose
whatsoever without the prior written consent of Owner, and that such
Proprietary Data received by Contractor shall be used by it exclusively in
connection with the performance of its responsibilities relating to the
Work.  However, nothing herein shall
prevent Contractor from disclosing Proprietary Data of Owner or its Affiliates
as required by Law or an order of a Government Authority; provided that
Contractor shall, if Contractor has adequate advance notice, give Owner
reasonable notice so as to allow Owner to seek a protective order or similar
protection, and nothing herein shall prevent Contractor from disclosing to the
appropriate Government Authority any noncompliance with or violation of laws,
rules, regulations, or orders within the jurisdiction of such Government
Authority.  If, in the opinion of its
legal counsel and in the absence of a protective order or waiver, Contractor is
legally compelled to disclose Owner’s Proprietary Data, Contractor will
disclose only the minimum amount of such information or data as, in the opinion
of its legal counsel, is legally required. 
In addition, Contractor shall have the right to receive and use
Proprietary Data of Owner (but

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-72-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

excluding any financial information) for the purposes
of performing or assisting in the performance of Startup, commissioning,
licensing and Startup maintenance services for other AP1000 Nuclear Power Plant
owners, and to disclose such Proprietary Data of Owner to such owners or
Subcontractors for such purposes under provisions of confidentiality including
an agreement substantially similar to Exhibit O-1, it being understood
that in such instances, Owner does not warrant such data and Contractor shall
indemnify Owner for any claims arising from the use of such data.  Nothing herein grants the right to Contractor
(or implies a license under any patent) to sell, license, lease or cause to
have sold, licensed or leased, any Proprietary Data supplied by Owner under
this Agreement.

 

(d)                                 Title to Proprietary Data provided by
Owner to Contractor and all copies made by or for Contractor in whole or in
part from such Proprietary Data remains with Owner.  Contractor shall include Owner’s confidential
or proprietary markings as provided by Owner on all copies thereof and excerpts
made therefrom except with respect to excerpts made or used internally by
Contractor for Facility Purposes; provided, however, that Contractor shall
destroy any such excerpts which do not include Owner’s confidential or
proprietary markings when no longer needed for the purpose for which they were
made.

 

19.2                           Protection of Contractor’s Proprietary
Data.

 

(a)                                  Any Proprietary Data of Contractor
disclosed to Owner shall be marked “Proprietary” [**]. If Owner  receives information which it recognizes as
being Proprietary Data, but which has not been marked as such, it shall
promptly notify Contractor and mark the information as Proprietary Data.

 

(b)                                 Owner’s Use.

 

(i)                                     Owner agrees not to use Proprietary Data
provided by Contractor or copies thereof unless such use is solely for the
purposes of [**].  Nothing herein grants
the right to Owner (or implies a license under any patent) to sell, license,
lease, or cause to have sold any Proprietary Data supplied by Contractor under
this Agreement.

 

(ii)                                  Title to Proprietary Data provided by
Contractor to Owner and all copies made by or for Owner in whole or in part
from such Proprietary Data remains with Contractor.  Owner shall include Contractor’s confidential
or proprietary markings as provided by Contractor on all copies thereof and
excerpts made therefrom except with respect to excerpts made or used internally
by Owner for [**]; provided, however, that Owner shall destroy any such
excerpts which do not include Contractor’s confidential or proprietary markings

 

“[**]” in this Exhibit 10.01 indicates material
that has been omitted pursuant to a request for confidential treatment and
filed separately with the Securities and Exchange Commission.

 

-73-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

when no longer needed for the purpose for which they
were made.  Except as otherwise provided
under this Section 19.2 or Section 19.3, Owner agrees to keep such
Proprietary Data confidential, to use such Proprietary Data only for [**] and
not to sell, transfer, sublicense, disclose or otherwise make available any of
such Proprietary Data to others (other than Affiliates).  However, nothing in this Article 19
shall prevent Owner from disclosing Proprietary Data of Contractor or its
Affiliates as required by Law or an order of a Government Authority (including,
without limitation, the COL); provided that Owner shall, if Owner has adequate
advance notice, give Contractor reasonable notice so as to allow Contractor to
seek a protective order or similar protection. 
If, in the opinion of Owner’s legal counsel and in the absence of a
protective order or waiver, Owner is legally compelled to disclose Proprietary
Data, Owner will disclose only the minimum amount of such information or data
as, in the opinion of Owner’s legal counsel, is legally required.  In any such event, Owner agrees to use good
faith efforts to ensure that Proprietary Data that is so disclosed will be
accorded confidential treatment.

 

(iii)                               Contractor hereby grants to Owner and its
Affiliates, officers, directors, employees or attorneys who have a need for
access to know such Proprietary Data reasonably related to the exercise of any
rights of the Owner hereunder a transferable (but only as part of the sale or transfer
of the Facility or the operating responsibilities related thereto),
royalty-free, fully paid up, perpetual and irrevocable (unless terminated for
the reasons  set forth in Sections  22.3, 22.4, or 22.5), nonexclusive license to
use and copy Contractor’s Proprietary Data but only for [**].

 

(iv)                              [**]

 

(c)                                  Owner’s Disclosure to Third Party
Recipients.

 

(i)                                     Owner may disclose Contractor’s
Proprietary Data to third parties (hereinafter referred to as “Recipients” or “Recipient”)
in accordance with the procedures and subject to the limitations set forth in
this Section 19.2 and Section 19.3, provided that such disclosure is
exclusively for [**]. Notwithstanding the foregoing, disclosures

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-74-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

of Contractor’s Proprietary Data (other than
Contractor Non-Disclosable Information) may be made to Recipients for the
purpose of evaluating the potential purchase of power from the Facility or in
the exercise of the rights of such purchasers to review Owner’s generation
expansion plans and such disclosures shall be governed exclusively by the
provisions of the existing Non-Disclosure Agreement among SCE&G, Santee
Cooper and the Consortium Members dated September 11, 2007, as amended
(the “Existing Confidentiality Agreement”).

 

(ii)                                  Owner shall enter into a proprietary data
agreement with the Recipient substantially on the terms set forth in Exhibit O-1;
provided, however, that the Owner may disclose such Proprietary Data without
entering into such agreements to those persons to which access is required by
any Government Authority or as necessary in order to comply with Law.

 

(iii)                               Should Owner discover a breach of the
terms and conditions of a proprietary data agreement with a third party, Owner
will promptly notify Contractor of such breach and provide to Contractor
necessary information and support pertaining to any suit or proceeding
contemplated or brought by Contractor against Recipient for such breach.

 

(iv)                              Contractor shall not be responsible to
Owner for the consequence of the use or misuse of Contractor’s Proprietary Data
by third parties. Contractor makes no warranties, express or implied, to the
extent of any such use or misuse of Contractor’s Proprietary Data by third
parties.

 

(v)                                 Nothing herein shall prevent Owner from
disclosing to the appropriate Government Authority any noncompliance or
violation of Laws within the jurisdiction of such Government Authority.

 

(d)                                 Owner’s Export of Technical Information. 
Owner agrees to comply with relevant United States Government
regulations concerning the export of technical information, with respect to
Contractor’s Proprietary Data provided to Owner by Contractor under this
Agreement.  This provision shall also
apply to any technical information developed by Owner using Contractor’s
Proprietary Data. Irrespective of any other provisions in this Agreement, the
obligations set forth in this Section 19.2(d) shall be binding so
long as the relevant United States Government regulations remain in effect.

 

19.3                           Special Procedures Pertaining to
Contractor’s Proprietary Data.

 

(a)                                  Categories of Contractor Proprietary Data. 
The Parties acknowledge and agree that certain Proprietary Data of
Contractor delivered to Owner under this Agreement in accordance with Table 2
of Exhibit A may be disclosed on a confidential basis without the
prior consent of Contractor (“Contractor Disclosable Information”, as described
in Section 19.3(b)), and that certain other Proprietary Data of Contractor
may not be disclosed by Owner to any third parties without the prior consent of
Contractor (“Contractor Non-Disclosable Information”, as described in Section 19.3(d)).
Owner agrees to abide by the provisions of this Section 19.3 governing the
disclosure of Contractor’s Proprietary Data.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-75-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

(b)                                 Contractor Disclosable Information. 
Contractor Disclosable Information consists of the following Proprietary
Data that has been developed by Contractor, to the extent such Proprietary Data
does not include Contractor Non-Disclosable Information as described in
Section 19.3(d) below:

 

(i)                                     [**];

 

(ii)                                  [**];

 

(iii)                               [**];

 

(iv)                              [**];

 

(v)                                 [**];

 

(vi)                              [**];

 

(vii)                           [**]; and

 

(viii)                        [**]:

 

(1)                                  [**]

 

(2)                                  [**]

 

(3)                                  [**]

 

(4)                                  [**]

 

(5)                                  [**]

 

(6)                                  [**]

 

(7)                                  [**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-76-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

(8)                                  [**]

 

(9)                                  [**]

 

(c)                                  Information. Contractor Disclosable Information may
be disclosed by Owner to third parties without prior notice to Contractor,
provided that such disclosure is exclusively for the Facility Purposes and
provided that:

 

(i)                                     Owner shall take reasonable steps to
minimize the disclosure of Contractor’s Proprietary Data to only that
information necessary for a Recipient to perform its contracted functions;

 

(ii)                                  Owner shall execute an agreement with the
Recipient governing the disclosure of Contractor’s Proprietary Data consistent
with Section 19.2(c)(ii);

 

(iii)                               Contractor has the right to audit Owner’s
records and the contents of any agreements (subject to Owner’s right to protect
Proprietary Data of Owner and third parties) executed between Owner and a
Recipient governing the disclosure of Contractor’s Proprietary Data (Owner
shall have the right to redact portions of such agreements not relevant to
confidentiality); and

 

(iv)                              The provisions of
Section 19.2(c)(iii), (iv) and (v) shall apply to such
disclosure.

 

(d)                                 Contractor Non-Disclosable Information. 
Contractor Non-Disclosable Information consists of the following
information that has been developed by Contractor:

 

(i)                                     [**];

 

(ii)                                  [**];

 

(iii)                               [**];

 

(iv)                              [**];

 

(v)                                 [**];

 

(vi)                              [**];

 

(vii)                           [**]; and

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-77-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

(viii)                        Information which contains confidential
intellectual property of Contractor’s Subcontractors or other Contractor
utility customers which is licensed to Contractor and which Contractor has the
right to sub-license to Owner, or confidential intellectual property of
Contractor’s Subcontractors licensed directly to Owner.  Exhibit O-2 contains the list of
such confidential intellectual property identified as of the Effective Date,
and these items are subject to the separate contractual or license agreements
and limitations on copying and use, and Owner agrees to and shall be bound by
the terms of any such third-party contractual or license agreements provided or
identified. The list in Exhibit O-2 will be updated by Contractor
during the Work as such additional third party license agreements are
identified and required as part of the Work and to update the list for any
newer versions or replacements of the software or other confidential
information, as applicable.  Contractor
shall not remove an item from Exhibit O-2 without Owner’s mutual
agreement.  For license agreements with
such third-parties necessary for maintenance or operation of the Facility for
items such as those identified in Exhibit O-2 but not previously
executed, Contractor agrees to make commercially reasonable efforts to negotiate
terms consistent with the provision of this Article 19 permitting
Contractor to sub-license to Owner confidential information received by
Contractor from Contractor’s Subcontractors or other contractor utility
customers.

 

(e)                                  Procedures Pertaining to Contractor
Non-Disclosable Information.  Upon written
request by Owner, Contractor shall consider the release of Contractor
Non-Disclosable Information. The request shall identify the information
requested to be disclosed, the work that is to be performed and the name of the
intended Recipient. The request shall be reviewed by Contractor for
acceptability for disclosure based on the principle, agreed to by Owner and
Contractor, that Contractor has the right to protect its proprietary
information in which it has made a substantial investment and which required
substantial innovation, balanced against whether such disclosure would
jeopardize such proprietary rights of Contractor and the principle that Owner
has the right to assure that services associated with maintenance and operation
of the Facility are in all respects prudent, including cost, and thus may need
to be performed by third party service providers. The determination of whether
or not to disclose the information shall be made by Contractor in its discretion
based on the above principles. [**]  If
Contractor agrees to the disclosure of such information, the specific
information to be provided to the Recipient (subject to Owner’s right to
protect Proprietary Data of Owner and Recipient) shall be subject to review and
approval by Contractor and shall be governed by the terms of the
confidentiality agreement with the Recipient substantially in the forms set
forth in Exhibit O-1.

 

(f)                                    Documents Containing Combined Information. Where a document marked “Proprietary”
or the like contains Contractor Disclosable Information and Contractor
Non-Disclosable Information, Owner shall not disclose any Contractor
Non-Disclosable Information without Contractor’s prior written consent.  Owner shall have the right to:

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-78-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

(i)                                     request Contractor to prepare and verify
the accuracy of a version of such document containing only Contractor
Disclosable Information;

 

(ii)                                  request Contractor to prepare and verify
the accuracy of a document which contains the specific information requested by
the third party service provider; or

 

(iii)                               itself extract the Contractor Disclosable
Information from such document and provide the Disclosable Information to the
third party service provider in accordance with the procedures set forth in
Section 19.3(c).  Owner shall make
commercially reasonable efforts to give notice to Contractor’s
currently-assigned designated contact of the proposed disclosure of any extract
of Contractor Disclosable Information and, at least five (5) Business Days
prior to such disclosure, shall provide such extract to Contractor for review.
All right, title and interest in Contractor Disclosable Information contained
in such document or material prepared by Owner remains with Contractor and, for
the avoidance of doubt, is hereby assigned to Contractor.

 

(iv)                              Contractor shall be reimbursed on a Time
and Materials Basis for the preparation and verification of documents for Owner
under Section 19.3(f)(i) and (ii) above.  Contractor shall assume no liability for, and
will not warrant the accuracy or validity of, any version of a document
containing Disclosable Information prepared by Owner pursuant to Section 19.3(f)(iii) above.

 

(g)                                 Additional Procedures. 
Owner and Contractor shall each designate a contact person for the
purposes of administering the disclosure of Contractor’s Proprietary Data.  Owner’s designated contact shall be
responsible for (i) ensuring that an agreement is executed with the Recipient
governing the disclosure of Contractor’s Proprietary Data consistent with
Section 19.2(b)(ii) before the information is released, and
(ii) making formal requests to Contractor for the release of information
designated as Contractor Non-Disclosable Information.  Contractor’s designated contact shall be
responsible for (i) handling and expediting responses to Owner’s requests
for release of information not specifically designated as disclosable and
(ii) conducting periodic reviews of Owner’s records listing the Recipients
and purposes of disclosure of Contractor Proprietary Data.

 

19.4                           Ownership of Rights in Documentation. 
The rights, title and interests in and to the copies of Documentation
provided to Owner shall be owned by Owner, provided that all rights, title and
interests in and to Contractor’s or third party’s Proprietary Data within the
Documentation shall remain with Contractor or the applicable third party,
subject to the provisions of this Article 19. The types of Documentation
to be received by Owner are listed in Table 2 of Exhibit A.

 

19.5                           Ownership of Invention Rights. 
Contractor shall retain the ownership rights in any and all discoveries
and inventions (patentable or unpatentable) that Contractor or any of its
Subcontractors makes, creates, develops, discovers or produces in connection
with the design, manufacture, testing, analysis, maintenance or construction of
the Facility or performance of the Work; provided, however, that Contractor
hereby grants to Owner a transferable (but only as part of the sale or transfer
of the Facility), royalty-free, fully paid up, irrevocable, nonexclusive

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-79-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

license to use such discoveries and inventions for the
purposes of Facility (and associated simulator) maintenance, operation,
training, repair, decommissioning and compliance with Laws.

 

19.6                           Software.  Software
provided to Owner by Contractor shall be subject to the software license
provisions set forth in Exhibit M-1.

 

19.7                           Publicity.  Each Party
shall use commercially reasonable efforts to consult with the other Party
before issuing any press releases or other public announcements involving any
details of this Agreement other than that the Parties are or have had
discussions with the other, except that the foregoing shall not be required if
necessary to comply with Law or in the case of an emergency.

 

ARTICLE
20 — ENVIRONMENTAL; HAZARDOUS MATERIALS

 

20.1                           Material Safety Data Sheets. 
To the extent required by applicable Law, Contractor shall provide to
Owner Material Safety Data Sheets covering Hazardous Materials to be furnished,
used, applied, or stored by Contractor, or any of its Subcontractors, at the
Site in connection with the Work. 
Contractor shall coordinate with Owner’s Project Director to provide a
listing of such Hazardous Materials and their quantities at the Site for
purposes of chemical inventory reporting pursuant to 40 C.F.R. Part 370
and similar state regulations.

 

20.2                           Facility Use, Storage Removal. 
When the use or storage of explosives or other Hazardous Materials or
equipment is necessary for the performance of the Work, Contractor shall
exercise the utmost care and shall carry on its activities under the
supervision of properly qualified personnel in accordance with applicable
Laws.  Before Unit Mechanical Completion
of the Second Unit (or if there is no Second Unit, the First Unit), Contractor
shall remove from the Site in accordance with applicable Laws any explosives
and other Hazardous Materials that Contractor or its Subcontractors used,
stored or located at the Site or any neighboring property, unless the same have
been permanently incorporated into the Facility, provided that, if any such
explosives and other Hazardous Materials are necessary for completion of the
Work, Contractor shall be permitted to retain such explosives and other
Hazardous Materials at the Site or any neighboring property but only if, and to
the extent, in compliance with the COL and applicable Laws.

 

20.3                           Handling, Collection, Removal
Transportation and Disposal.

 

(a)                                  Unless otherwise agreed by the Parties,
Contractor shall be responsible for the proper handling, treatment, collection,
containerizing and removal of Hazardous Materials brought onto the Site or
created by Contractor or Subcontractors or spilled or introduced into or at the
Site by Contractor or any Subcontractor, including any such Hazardous Materials
furnished, used, applied or stored at the Site by Contractor or any
Subcontractor, including used oils, greases, and solvents from flushing and
cleaning processes performed under the Agreement.  Prior to Unit Mechanical Completion of a
Unit, Contractor shall be responsible for the proper handling, storage,
transportation, and disposal of any Hazardous Materials brought onto the Site
or created by Contractor or Subcontractors. Contractor shall be liable for any
fines or penalties imposed for its or its Subcontractors’ failure to comply
with applicable Laws with respect to Hazardous Materials for which it is
responsible pursuant to this Section 20.3(a).

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-80-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

(b)                                 At all times during the performance of
the Work, Owner shall be responsible for the prompt and proper handling,
storage, transportation and disposal of Hazardous Materials existing at, on or
under the Site that were not brought onto the Site or created by Contractor or
Subcontractors. After Unit Mechanical Completion of a Unit, Owner shall be
responsible for the prompt and proper handling, storage, transportation and
disposal of Hazardous Materials used or generated with respect to such Unit or
remaining at the Site (after proper handling, collection and containerizing by
Contractor). As between the Parties, Owner shall be considered the generator for
Hazardous Materials existing at, on or under the Site that were not brought
onto the Site or created by Contractor or Subcontractors, and shall retain all
responsibility and liability with respect to such Hazardous Materials.  Subject to limitations on Santee Cooper’s
obligations as a matter of South Carolina law and subject to Contractor’s
obligations under Section 20.3(a), Owner shall indemnify Contractor
against any penalties levied by any Government Authority for allowing any
collected and containerized waste remaining in storage for more than the period
allowed by applicable Laws without permit.

 

(c)                                  Activities performed by each Party in
connection with the handling, storage, collection, containerizing,
transportation and disposal of Hazardous Materials shall be performed in
accordance with the requirements of all Government Authorities and all
applicable Laws.

 

20.4                           Notice of Discovery. 
Contractor shall provide prompt written notice to Owner of any suspected
Hazardous Materials that Contractor finds during performance of the Work not
previously identified by Owner to Contractor. 
Owner shall be responsible for any further action required after the
discovery. To the extent any such action causes an increase in Contractor’s
costs or a delay in the performance of the Work, Contractor shall be entitled
to a Change Order pursuant to Article 9.

 

ARTICLE
21 — TITLE; RISK OF LOSS

 

21.1                           Transfer of Title. 
Except as otherwise expressly provided in this Agreement, title to an
item of Equipment shall pass to Owner upon payment in full by Owner to
Contractor for such item of Equipment. 
The passage of title to Owner shall not be deemed an acceptance or
approval of such Equipment (or any Work), affect the allocation of risk of
loss, or otherwise relieve Contractor or Owner of any obligation under this
Agreement to provide and pay for transportation and storage in connection with
the Equipment.

 

21.2                           Risk of Loss.

 

(a)                                  Whether or not title has passed to Owner,
the risk of loss for each system or structure of a Unit shall remain with
Contractor until, and shall pass to Owner upon Turnover of such system or
structure. Contractor shall be obligated to replace, repair or reconstruct the
Equipment that is lost, damaged, or destroyed before the risk of loss of the
Equipment is transferred to Owner, provided that Contractor is reimbursed for
performing such replacement, repair, or reconstructions, as applicable, from
the Builder’s Risk insurance described in Sections 16.1(b) and
16.2(a)(ii) or as otherwise provided herein.  Notwithstanding the foregoing, and
notwithstanding any provision of this Agreement that requires a Party to bear
the risk of loss to its own property, during the Turnover process, and until
Unit Mechanical Completion and

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-81-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

thereafter, (i) if Owner or any of its Personnel
or Invitees damages any part of a system or structure of a Unit that has not
yet achieved Turnover, Owner shall reimburse Contractor on a Time and Materials
Basis  to the extent of the negligence of
Owner, its Personnel or Invitees, for any amounts not reimbursed by the
applicable insurance policy, including the insurance deductibles related to
such loss and (ii) if Contractor or any of its Personnel or Invitees damages
any part of a system or structure of a Unit that has achieved Turnover,
Contractor shall be liable for the insurance deductibles related to such loss
subject to and limited by Section 16.2(a)(ii).

 

(b)                                 Risk of loss to Equipment that Contractor
removes from the Facility or from the Site for repair, replacement or
refurbishment under the Warranty shall transfer to Contractor at the time of
its loading on the carrier at the Facility. 
Owner shall reassume the risk of loss upon completion of the unloading of
the Equipment from the carrier at the Facility upon completion of such
replacement, refurbishment or repair services.

 

21.3                           Risk to a Party’s Property. 
Each Party is responsible for insuring its own property (including the
Facility and surrounding property) during the Work and thereafter, and each
Party shall extend the benefit of such property insurance to the other. Each
Party on behalf of itself and its insurers hereby waives all rights of recovery
(including subrogation rights) against the other Party (including Contractor
Interests) for any loss or damage to its property during the Work and
thereafter, including the deductibles under any insurance policy.
Notwithstanding the foregoing, however, should a Party cause damage to the
other Party’s property (including the Facility and surrounding property), such
Party shall be responsible for the other Party’s deductible under its insurance
policy, up to (and limited to) [**].  For
the avoidance of doubt, Contractor’s liability for the payment of such amount
shall not be reimbursable hereunder. 
Owner shall reimburse Contractor on a Time and Materials Basis for  its work to remedy such loss or damage that
exceeds such amount, whether based on contract, tort (including fault,
negligence and strict liability) or otherwise. 
The foregoing shall apply notwithstanding any other provision to the
contrary.

 

ARTICLE
22 — SUSPENSION AND TERMINATION

 

22.1                           Suspension by the Owner for Convenience.

 

(a)                                  Owner may, without cause, order
Contractor in writing to suspend, delay or interrupt the Work in whole or in
part for such period of time as Owner may determine. Any such suspension of the
Work shall entitle Contractor to a Change Order pursuant to Article 9.

 

(b)                                 Owner shall continue to meet the payment
obligations to Contractor during any suspension, delay or interruption for Work
actually performed.

 

(c)                                  During any suspension, Contractor shall
take reasonable precautions to protect, store and secure the Equipment against
deterioration, loss or damage and to minimize the charges for the suspension.

 

(d)                                 Contractor shall resume any suspended
Work promptly following receipt of notice from Owner to do so.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-82-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

22.2                           Termination by Owner for Cause.

 

(a)                                  Without limiting any other rights that it
may have hereunder, Owner may terminate the Agreement upon notice to Contractor
if:

 

(i)                                     Contractor is in breach of a material
provision of this Agreement and fails to cure the breach within [**] following
written notice of such breach or, if such breach is not capable of being cured
within such [**] period, such longer period as is reasonably necessary so long
as Contractor has commenced the cure within such [**] period and thereafter
diligently pursues the cure;

 

(ii)                                  [**];

 

(iii)                               unless due to an Uncontrollable
Circumstance, Substantial Completion of a Unit is delayed by more than [**]
past the Guaranteed Substantial Completion Date for such Unit and Contractor is
not, in the reasonable opinion of Owner, exercising due diligence to correct
same; or

 

(iv)                              a Consortium Member is Insolvent.

 

(b)                                 When Owner terminates the Agreement for
one of the reasons stated in Section 22.2(a), Contractor shall not be
entitled to receive further payment until the Work is finished subject to the
provisions set forth in Section 22.2(c)(iii).

 

(c)                                  Upon any termination pursuant to this
Section 22.2, Owner may at its option elect to: (i) assume
responsibility for and take title to and possession of the Facility and Work
and Equipment remaining at the Site and Equipment located outside the Site for
which payment in full or in part has been made by Owner; (ii) succeed
automatically, without the necessity of any further action by Contractor, to
the interests of Contractor in any or all Subcontracts entered into by
Contractor with respect to the Work (if such Subcontracts permit), and shall be
required to compensate such Subcontractors if acceptable to such Subcontractors
only for compensation becoming due and payable to such parties for goods and
services provided under the terms of their Subcontracts with Contractor from
and after the date Owner elects to succeed to the interests of Contractor in
such Subcontracts and (iii) request that Contractor continue to perform
the Work or any portion thereof pursuant to a separate agreement.  In the event of any termination pursuant to
this Section 22.2, Owner may, at its option, finish the Work and other
work by whatever method Owner may deem expedient.

 

(d)                                 If the unpaid balance of [**] exceeds the
costs of finishing [**] the Work (including all reasonable administrative and
other direct costs incurred as a result of such termination), such excess shall
be paid to Contractor. If the cost of finishing [**] the Work

 

“[**]” in this Exhibit 10.01 indicates material
that has been omitted pursuant to a request for confidential treatment and
filed separately with the Securities and Exchange Commission.

 

-83-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

(including all reasonable direct costs for Owner to
administer the completion of the Work and other direct costs incurred by Owner
as a result of such termination) exceeds the unpaid balance of [**], Contractor
shall pay the difference to Owner.

 

(e)                                  [**]

 

22.3                           Termination by Owner for Convenience.

 

(a)                                  Owner may, at any time, terminate the
Agreement for Owner’s convenience and without cause.

 

(b)                                 In the event of termination for Owner’s
convenience prior to the issuance of the Full Notice to Proceed, Contractor
shall be entitled to receive payment for its Termination Costs.

 

(c)                                  If Owner terminates for its convenience
after the issuance of the Full Notice to Proceed, Contractor shall be entitled
to receive payment for its Termination Costs and Owner shall pay to Contractor
a termination fee of [**]. [**] In the event that Owner has exercised its right
under Section 3.3(b) to cancel the Second Unit prior to issuance of
the Full Notice to Proceed and, subsequent to issuance of the Full Notice to
Proceed but within one (1) year following the cancellation of the Second
Unit, terminates this Agreement for its convenience, the Profit shall be
determined as if both Units were cancelled after issuance of the Full Notice to
Proceed. The one (1) year period described in the preceding sentence shall
be extended by the duration of any period of suspension of the Work pursuant to
Section 22.1 that is initiated during such one (1) year period.

 

(d)                                 Upon such termination and payment, the Parties
shall have no further liability to one another other than any liability that
arose prior to the termination of this Agreement pursuant to this
Section 22.3 and the Parties’ obligations under Section 22.6.

 

22.4                           Suspension and Termination Due to Other
Circumstances.

 

(a)                                  In the event that Owner does not issue
the Full Notice to Proceed as established in Section 3.3(b), Contractor
shall have the right to suspend its Work, demobilize its forces and take such
other actions as are reasonably needed to address the consequences of a delay
in the Work, including the suspension or cancellation, as applicable of the
Work being performed under Subcontracts. Prior to initiating such suspension,
Contractor shall issue a notice

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-84-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

to Owner stating the basis for such suspension. Once
the event that allowed Contractor to suspend Work under this
Section 22.4(a) has occurred, Owner and Contractor shall negotiate a
Change in the Contract Price, Project Schedule (including the Guaranteed
Substantial Completion Date(s)), and such other applicable terms and conditions
of this Agreement to reflect the effect of such event, including, without
limitation, the suspension of the Work, and the demobilization and
remobilization of Contractor’s and the Subcontractors’ forces, as applicable.
Contractor shall incorporate agreed upon changes in a Change Order[**]. [**]

 

(b)                                 Either Party may terminate this Agreement
in the event that DOE fails to fund all NuStart AP1000 Nuclear Power Plant COL
activities and AP1000 Nuclear Power Plant design finalization substantially on
the schedule set forth in Exhibit E, and within [**] following such
failure, the Parties have not agreed, pursuant to good faith negotiations, on an
alternative funding method satisfactory to the Parties;

 

(c)                                  In the event that through no act or fault
of Contractor or a Subcontractor, one or more suspensions, delays or
interruptions of the Work by Owner or due to an Uncontrollable Circumstance
constitute in the aggregate more than [**] or more than [**] out of any [**]
period, or (unless due to a breach by Contractor of its obligations under this
Agreement or a failure by Contractor to comply with applicable Law) an order of
a Government Authority having jurisdiction over the Facility which requires the
Work to be permanently stopped (or stopped for greater than one year),
Contractor shall have the right to notify Owner that it intends to terminate
the Agreement. If Owner does not agree to such termination within [**]
following Contractor’s notice, Owner and Contractor shall negotiate a Change in
accordance with Article 9 to reflect the effect of suspension, delay or
interruption of the Work. Contractor shall incorporate agreed upon changes in a
Change Order or, in the absence of agreement, shall prepare a proposed Change
Order reflecting the changes it deems necessary to reflect the effect of the
suspension, delay or interruption. Within [**] following receipt of the
requested Change Order from Contractor, Owner shall notify Contractor whether
it (i) accepts the Change Order as proposed by Contractor,
(ii) desires to have disputed issues in the Change Order resolved under
the terms of Article 27 or (iii) desires to terminate this Agreement.
If Owner does not (x) accept the Change Order as proposed by Contractor,
(y) notify Contractor of its desire to have disputed issues resolved under
Article 27 or (z) issue notice of termination within such [**]
period, Contractor shall have the right to terminate this Agreement upon [**]
notice to Owner.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-85-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

(d)                                 [**]

 

(e)                                  In the event of termination pursuant to
this Section 22.4, Contractor shall be entitled to receive payment for its
Termination Costs; [**].

 

22.5                           Termination by Contractor.

 

(a)                                  Contractor may terminate this Agreement
for any of the following reasons:

 

(i)                                     Owner fails to make payment to Contractor
in accordance with the Agreement for a period exceeding [**] after an
undisputed invoice has become due, or Owner fails to make payment to Contractor
of disputed amounts in accordance with the provisions of
Section 8.4(b)(i) for a period exceeding [**] following the date
provided for in Section 8.4(b)(i), provided, in either case, that Contractor
has provided the notices of overdue payment as required under
Section 8.4(c);

 

(ii)                                  Owner is in breach of a material
provision of this Agreement and fails to cure the breach within [**] following
written notice of such breach or, if such breach is not capable of being cured
within such [**] period, such longer period as is reasonably necessary so long
as Owner has commenced the cure within such [**] period and thereafter
diligently pursues the cure; or

 

(iii)                               Either SCE&G or Santee Cooper is
Insolvent unless the other of SCE&G or Santee Cooper has provided security
for payments that would be due from such Insolvent Person in accordance with
Section 8.6 and no other changes to this Agreement have resulted from
proceedings involving the Person that is Insolvent.

 

(b)                                 Upon termination of this Agreement
pursuant to this Section 22.5, Contractor shall be entitled to receive
payment from Owner as if it were a termination for Owner’s convenience under
Section 22.3.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-86-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

22.6                           Actions Required of Contractor upon
Termination.  Upon receipt of a notice of termination from
Owner or the issuance of a notice of termination by Contractor, Contractor
shall:

 

(a)                                  in an orderly manner and consistent with
safety considerations, cease operations as directed by Owner in the notice;

 

(b)                                 take actions necessary, or that Owner may
direct, for the protection and preservation of the Work (wherever located); and

 

(c)                                  except for Work directed to be performed
prior to the effective date of termination stated in the notice, enter into no
further contracts and purchase orders.

 

Upon receipt of a notice of termination for
convenience from Owner, a notice of termination for cause from Owner pursuant
to Section 22.2, or a notice of termination from Owner or Contractor, as
applicable, pursuant to Section 22.4, Contractor shall use commercially
reasonable efforts for a commercially reasonable time to sell to a third party
the Equipment for which Owner has made Milestone Payments or to cancel such
Equipment orders. Contractor shall consult with Owner with respect to such sale
or cancellation to determine which is the preferred course of action. If
Contractor sells the Equipment to a third party, then the net sales price for
the Equipment paid to Contractor shall be remitted to Owner when received by
Contractor. If Contractor determines that it is able to use the Equipment for
another customer, the price to be charged to the other customer for such
Equipment shall be refunded to Owner as such payments are received from the
other customer.  If Equipment for which
Owner has made Milestone Payments cannot be sold, cancelled or designated for
another customer, then, at Owner’s request, Contractor shall assign to Owner,
and Owner shall assume, all rights and obligations under such Subcontract.
Owner shall pay Contractor for such activities on Owner’s behalf as follows:
(i) for Westinghouse, its Recoverable Costs plus SGA and Pro Rata Profit
on such costs and (ii) for Stone & Webster, its costs and
expenses on a Time and Materials Basis. 
In each instance under this Article 22 in which Termination Costs
are due from Owner, such Termination Costs shall be determined following the
performance of the undertakings of Contractor pursuant to this paragraph (other
than the obligation to refund to Owner amounts received from a third party or
another customer as provided above).

 

ARTICLE
23 – SAFETY; INCIDENT REPORTING

 

23.1                           Environmental, Health and Safety Programs. 
Contractor shall be responsible for initiating, maintaining and
supervising the safety precautions and programs in connection with its
performance of its Work under the Agreement, including necessary precautions
and programs for the Site and any areas adjacent to the Site under its
supervision and/or control.  Contractor
shall comply with applicable workplace safety Laws governing the Work and/or
Site.

 

23.2                           Designated Contractor Safety
Representative.  Contractor shall designate a responsible,
qualified person in Contractor’s organization at the Site whose duty shall be
the prevention of incidents and injuries and addressing unsafe and undesirable
conditions and behavior for each of the following three (3) areas:
environmental matters (U.S. Environmental Protection Agency and any applicable
state agency), health matters (industrial hygiene and

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-87-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

employee health hazard prevention/mitigation) and
safety matters, as each area relates to construction activities generally and
the Work specifically.  One individual
may be designated for more than one of these three areas if the individual is
qualified in the relevant areas.

 

23.3                           OSHA and Other Laws. 
Contractor shall provide notices and comply with applicable workplace
safety Laws, including the Occupational Safety and Health Act (“OSHA”) and
provisions of the Americans with Disabilities Act relevant to workplace safety.
Contractor shall maintain the logs required under OSHA.

 

(a)                                  Contractor represents that it is familiar
with the Site, the Work to be performed, the Equipment to be provided, the
hazards of the Work, and, if applicable, the Material Safety Data Sheets for,
and the hazards of, the Hazardous Materials that Contractor is expected to
provide. Contractor represents that it is familiar with the labeling system
used in the workplace.

 

(b)                                 Contractor acknowledges that OSHA and
regulatory standards or state plan equivalent (collectively, the “OSHA
Standards”) require that its employees be trained in various subjects, such as,
but not limited to, the hazards of, and standards applicable to, the Work (29
C.F.R. § 1926.21(b)(2)) (applicable to construction work), lockout/tagout (29
C.F.R. § 1910.147), confined space entry (29 C.F.R. §§
1926.21(b)(6) or 1910.146), and asbestos (29 C.F.R. §§ 1910.1001 or
1926.1101).  Prior to performing Work on
the Site, Contractor’s employees and their supervisors shall, as required, have
been trained in accordance with all applicable OSHA Standards relating to the
duties they perform or supervise, and they shall have been trained to recognize
and avoid any hazards related to the Work, and to perform the Work safely and
without danger to any employee or to any property.

 

(c)                                  Contractor represents that its employees
are or shall be equipped with the personal protective equipment required by
applicable OSHA Standards in 29 C.F.R. Parts 1926 and 1910, and with the
personal protective equipment required to protect its employees against other
serious health or safety hazards. 
Contractor agrees that it shall discipline its employees who violate any
OSHA Standards or applicable Laws in accordance with its own policies and
procedures.

 

(d)                                 Contractor shall comply with all OSHA
Standards applicable to the Work, including those requiring pre-employment
testing of employees, such as, but not limited to, pulmonary testing, blood
testing, urine testing, hearing testing, respirator fit testing, drug
screening, and/or applicable medical surveillance testing.

 

(e)                                  Contractor shall comply with its safety
programs and/or any Site specific safety plans which Owner has reviewed and
accepted.

 

(f)                                    Within a reasonable time following a
specific request by Owner, and to the extent permitted by applicable Law,
Contractor shall provide to Owner copies of training materials for its
employees concerning a particular safety and health standard and/or particular
substantive or technical training requirement of the job.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-88-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

23.4                           Worksite Safety.

 

(a)                                  Contractor shall take reasonable
precautions for the safety of, and shall provide reasonable protection to
prevent damage, injury or loss to Persons and property resulting from the Work,
including:

 

(i)                                     Contractor or Subcontractor employees and
other Persons performing the Work and any Persons who may be affected by the
performance of the Work;

 

(ii)                                  the Equipment to be incorporated into the
Facility, whether in storage on or off the Site or under the care, custody or
control of Contractor or Subcontractors; and

 

(iii)                               other property at or adjacent to the
Site, including trees, shrubs, lawns, walks, pavements, roadways, structures
and utilities.

 

(iv)                              Contractor shall erect, maintain or
undertake, as required by existing conditions and the performance of the
Agreement, reasonable safeguards for the safety and protection of Persons and
property, including posting danger signs and other warnings against hazards,
promulgating safety regulations, and notifying Owner and users of adjacent
sites and utilities.  Those precautions
may include providing security guards.

 

(v)                                 Contractor agrees to provide to Owner the
name, title, and phone number of its emergency contact person prior to the
commencement of the Work.

 

23.5                           Dangerous Materials. 
When the use or storage of explosives or other dangerous materials or
equipment or unusual methods are necessary for the Work, Contractor shall
exercise utmost care and carry on its activities only under the supervision of
properly qualified personnel.  Contractor
shall notify Owner’s Project Director prior to bringing any explosives onto the
Site.

 

23.6                           Cooperation in Governmental
Investigations and Inspections.  Contractor
and its Subcontractors shall provide reasonable assistance to Owner in
responding to requests and inspections by any Government Authority for
information in connection with the Work involving Contractor or its
Subcontractors.  Contractor shall provide
the NRC the facilities, furnishings, conveniences and access set forth in 10
C.F.R. § 50.70 and shall take good faith efforts to keep confidential the
presence of any representative of the NRC at the Site as provided in 10 C.F.R.
§ 50.70(b)(4).

 

23.7                           Audit.  To the extent
permitted by applicable Law, and in response to specific and identifiable
concerns, Contractor shall permit Owner to review and copy Contractor’s
documents related to those specific and identifiable safety and health concerns
at the Site.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-89-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

ARTICLE
24 – QUALIFICATIONS AND PROTECTION OF ASSIGNED PERSONNEL

 

24.1                           Screening Measures. 
A fitness for duty and security screening program (“Screening Measures”)
shall be established for all Contractor and Subcontractor employees for the
Work. This program shall comply with the regulations set forth in the Laws
governing new nuclear build construction. This program shall contain:

 

·                                          Prohibition of the use, transportation,
sale, or possession of illegal drugs

 

·                                          Prohibition of the use or possession of
alcohol beverages on the Site

 

·                                          Requirement that employees be fit for
duty at all times while on the Site

 

·                                          Requirement that employees submit to drug
and alcohol testing during preaccess screening, for-cause testing, and post
event testing, as necessary

 

·                                          Requirement that all employees must
immediately report known, suspected, or potential violations of this policy to
supervisory personnel or management

 

·                                          Requirement that a subset of workers who
perform important safety functions be subject to random testing

 

·                                          Protection of information and records to
assure confidentiality

 

·                                          Requirement that employees consent to a
search or inspection of the individual’s property while on the Site.

 

In addition to pre-access screening for drugs and
alcohol an identity check and screening for criminal history shall be
performed.  A law enforcement criminal
records check on all potential employees that shall include:

 

·                                          Verification of identity

 

·                                          A criminal history check of the
individual shall be performed

 

·                                          Prior to a final adverse determination,
the applicant shall be informed of the basis for potential denial of access to
the Site to assure the accuracy of the basis for such denial.

 

During preaccess screening a probationary period of
not to exceed thirty (30) Days shall be granted to allow for the testing and
prescreening to be performed while the employee is put to work.

 

24.2                           Contractor’s Personnel. 
Contractor shall comply with applicable labor and immigration Laws that
may impact Contractor’s Work under this Agreement, including the Immigration
Reform and Control Act of 1986 and Form I-9 requirements.  Contractor
shall perform the required employment eligibility and verification checks and
maintain the required employment records.  Contractor acknowledges and
agrees that it is responsible for conducting

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-90-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

adequate screening of its employees and agents prior
to starting the Work.  By providing an employee or Subcontractor under
this Agreement, Contractor warrants and represents that the Screening Measures
with respect to such employee or Subcontractor have been completed and that
such Screening Measures did not reveal any information that could adversely
affect such employee’s or Subcontractor’s suitability for employment or
engagement by Contractor or competence or ability to perform duties under this
Agreement.  If in doubt whether a suitability, competence or ability
concern exists, Contractor shall discuss with Owner the relevant facts and
Owner shall determine, in its sole discretion, whether such Person should be
allowed to perform the Work.  Owner, in its sole discretion, shall have
the option of barring from the Site any person whom Owner determines does not
meet the qualification requirements set forth above.  In all circumstances,
Contractor shall ensure that the substance and manner of any and all Screening
Measures performed by Contractor pursuant to this Section conform fully to
applicable Law.  Contractor shall submit to Owner for approval a set of
work rules that applies to all Contractor and Subcontractor
employees. This set of work rules shall establish Contractor’s and
Subcontractor’s disciplinary action policy and hiring and termination
policy.  This policy shall detail the actions
to be taken by Contractor and Subcontractors for acts of misconduct, negligence
and incompetence of their employees. The disciplinary action program shall be
progressive up to termination and the barring of employee from future
employment.

 

24.3                           Training of Employees. 
Contractor represents that all Contractor and Subcontractor personnel
shall as required be trained regarding environmental, OSHA and NRC requirements
and any other matters required by applicable Laws and relevant to the Work.

 

24.4                           NRC Whistleblower Provision. 
Contractor and its Major Subcontractors shall comply with the
requirements of Section 211, “Employee Protection,” of the Energy
Reorganization Act of 1974, 42 U.S.C. § 5851, as amended; 10 C.F.R. § 50.7,
“Protection of Employees Who Provide Information” and 29 C.F.R. § 24 (collectively,
the “Whistleblower Provisions”). 
Contractor shall implement a program and develop procedures to advise
all of Contractor’s and the Major Subcontractors’ personnel that they are
entitled and encouraged to raise safety concerns to Contractor’s management, to
Owner, and to the NRC, without fear of discharge or other discrimination.

 

24.5                           Respirator Protection. 
For any Work at the Site that shall expose any of Contractor’s or any
Subcontractor’s employees or representatives to sources of radiation or require
them to wear respiratory protection, Contractor shall require each of these
employees or other representatives, prior to entering any radiation area or
wearing respiratory protection, to undergo a physical examination to determine
if occupational radiation exposure or the wearing of respiratory protection
should be avoided because of any medical condition or other circumstance, and
in addition, to undergo such physical examination as may be required by
applicable Law or by any Government Authority having jurisdiction.  Contractor shall keep a record of the
physical examination available for inspection by Owner.  Owner shall assist Contractor in defining the
applicable requirements, if requested.

 

ARTICLE
25 – RECORDS AND AUDIT

 

25.1                           Technical Documentation. 
Except to the extent applicable Laws require a longer retention,
Contractor shall maintain and shall cause its Major Subcontractors to maintain
all

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

-91-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

technical documentation relative to the Equipment for
a period of [**] after Final Completion.

 

25.2                           Accounting Records. 
Except to the extent applicable Laws require a longer retention,
Contractor shall maintain and shall cause its Subcontractors to maintain
complete accounting records relating to the Work performed or provided under
this Agreement on a Time and Materials Basis or the Target Price, or other
reimbursable basis in accordance with generally accepted accounting principles
in the United States, as set forth in pronouncements of the Financial
Accounting Standards Board (and its predecessors) and the American Institute of
Certified Public Accountants, for a period of [**] after Final Completion of a
Unit, except that records relating to Sales Taxes for such items must be
retained for [**] as specified in Section 25.5.

 

25.3                           Maintenance of Records Generally. 
Notwithstanding anything in Section 25.1 or 25.2 to the contrary,
Contractor shall ensure that its maintenance of records complies with the
applicable provisions of 10 C.F.R. § 50.71.

 

25.4                           Right to Audit. 
If Owner requests verification of Recoverable Costs claimed by
Contractor for reimbursement or for any Work performed or provided on a Time
and Materials Basis or the Target Price, Owner or its authorized representative
shall be permitted to examine and audit Contractor’s records and books, and
Subcontractors’ where permitted by contract, related to those costs.  The right to initiate any audit shall expire,
with respect to any such cost, [**] after the cost was incurred. Such audit
shall provide Owner with a reasonable opportunity to verify that all costs and
charges have been properly invoiced in accordance with the terms of this
Agreement. Owner shall not be entitled to any information that would enable
Owner to determine [**] unless access to this information is needed to support
a request made by Owner or Contractor for a change in indices in accordance
with Article 7.  If any audit by the
auditor reveals charges to or paid by Owner as charges or fees which are
incorrectly charged, then Owner shall be entitled upon demand for a refund from
Contractor of such amounts, together with interest at [**] per annum, measured
from the date of the incorrect invoice until the date the refund is paid.  Likewise, if any audit or if any examination
by any state or local taxing agency reveals additional Sales Tax to be imposed
upon Contractor for under collection of tax from Owner on a taxable sale, then
Contractor shall be entitled, upon demand, to a payment from Owner of all such
amounts, together with any interest and penalties imposed by any state or local
taxing agency.  Notwithstanding anything
in this Section 25.4 to the contrary, Owner shall not be restricted from
any audit rights, including any right to conduct audits directly without any
intermediary, which it is required to have in order to comply with applicable
Laws, including the regulations of the NRC.

 

25.5                           Sales Tax Records. 
Contractor shall provide or provide access to the information,
documents, receipts, invoices, and data to Owner on a monthly basis, or as
Owner may from time to time reasonably request and as may be specifically
required by the South Carolina state tax regulations for non-tax exempt items,
and otherwise fully cooperate with Owner in connection with the reporting of
(a) any Sales Taxes payable with respect to the Work and (b) any

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-92-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

assessment, refund claim or proceeding relating to
Taxes payable with respect to the Work. 
This may include a monthly assessment visit from the South Carolina
state tax department to review this information.  Contractor shall require its Major
Subcontractors to provide to Contractor all information and data Contractor may
reasonably request for purposes of complying with this Article and
otherwise fully cooperate with Owner. Contractor shall retain, and shall
require Major Subcontractors to retain, copies of such documentation and all
documentation relating to purchases relating to the Work or the payment of
Sales Taxes, if any, for a period of not less than [**].  Contractor shall ensure that its contracts
with all Major Subcontractors effectuate the provision of this
Section 25.5.  Contractor’s
obligations under this Section shall survive the termination, cancellation
or expiration of this Agreement for any reason and shall last so long as is
necessary to resolve any and all matters regarding Taxes attributable to the
Work.  This information is intended
solely for the use of tax compliance.

 

ARTICLE
26 – TAXES

 

26.1                           Employment Taxes. 
Contractor shall be responsible for payroll or employment compensation
taxes, Social Security taxes, or for labor-related withholding taxes for
Contractor and its Subcontractors or any of their employees (“Employment
Taxes”).

 

26.2                           Sales and Use Taxes on Contractor Tools. 
Contractor shall pay the taxes on Contractor’s purchases of goods,
tools, equipment, supplies and other consumables which are not permanently
incorporated into the Facility and which remain the property of
Contractor.  Contractor shall also pay
the taxes attributable to Contractor’s Construction Equipment, temporary
buildings and other property used by Contractor in its performance of this
Agreement.  Allowance for such taxes is
included in the Firm Price and Fixed Price, and Contractor shall pay those
taxes when assessed, without claim against Owner for reimbursement for Work
under the Firm Price and Fixed Price, but shall be reimbursed for such charges
for Work under the Target Price and for Work performed on a Time and Materials
Basis.  Contractor shall impose a similar
obligation on all Subcontractors and shall ensure that no Subcontractor
providing Firm Price or Fixed Price Work shall have any claim against Owner for
reimbursement of those taxes.

 

26.3                           Sales and Use Tax on Equipment. 
Notwithstanding the above, the Firm Price, Fixed Price and Target Price
does not include monies for the payment of any sales and use taxes on Equipment
incorporated into the Facility. 
Contractor shall consult with Owner on Equipment purchases and work with
Owner to obtain the most favorable sales and use tax benefits for Owner.

 

26.4                           State Property Taxes. 
Contractor and Owner agree that Owner shall be responsible for the
filing requirements and payment obligations for all state and local taxes on
the Site and the Equipment incorporated (and to be incorporated) into the
Facility, provided that Contractor shall be responsible for the filing of
property tax returns and the payment of state and local property taxes on
Construction Equipment, tools and material which are not incorporated into the
Facility and which are owned, used or leased by Contractor to perform the Work.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-93-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

26.5                           Tax Indemnification.

 

(a)                                  Except in cases where the imposition of
any Tax is the result of the negligence or willful or wanton misconduct by
Contractor, Owner shall defend, reimburse, indemnify and hold Contractor
harmless for the costs and expenses (including any resulting Taxes, interests
and penalties) incurred by Contractor as a result of (i) Owner’s formal
protest to any Government Authority of any Employment Taxes or Sales Taxes paid
or assessed or any property taxes paid or assessed by Government Authorities on
the Site or the Equipment, or any other similar Tax, whether local, state or
federal, including any litigation expenses in the event Owner decides to
protest any such Taxes or (ii) an audit or other investigation by any
Government Authority, including the defense and any resulting Tax liability in
connection therewith. Owner shall not be responsible for any costs incurred by
Contractor necessary to substantiate or verify information for any Tax audit
conducted by any Government Authority in the normal course of business.

 

(b)                                 Except in cases where the imposition of
any Tax is the result of the negligence or willful or wanton misconduct by
Owner, Contractor shall defend, reimburse, indemnify and hold Owner harmless
for the costs and expenses (including any resulting Taxes) incurred by Owner as
a result of (i) Contractor’s formal protest to any Government Authority of
any Employment Taxes, or any Sales Tax or any property tax paid or assessed by
any Government Authority on Contractor’s Construction Equipment, tools and
materials that are not incorporated into the Facility, or any other similar
Tax, whether local, state or federal, including any litigation expenses in the
event Contractor decides to protest any such Taxes or (ii) an audit or
other investigation by any Government Authority, including the defense and any
resulting Tax liability in connection therewith. Contractor shall not be
responsible for any costs incurred by Owner necessary to substantiate or verify
information for any Tax audit or investigation conducted by any Government
Authority in the normal course of business.

 

26.6                           Pollution Control Equipment Information. 
Contractor shall supply Owner with all reasonable information requested
by Owner for qualifying air, water or noise pollution control and other
equipment for exemption from sales and use taxes, property taxes and any other
tax credits, refunds or exemptions available to Owner.  Owner shall supply Contractor with all
reasonable information and cost analyses requested by Contractor for qualifying
air, water or noise pollution control equipment for exemption from sales and
use taxes, property taxes and any other credits, refunds or exemptions
available to Contractor.

 

26.7                           Non-resident Contractor. 
Contractor shall comply with Section 12-8-550 of the Code of Laws
of South Carolina (1976), as amended, which requires any nonresident contractor
providing labor in the State of South Carolina to register with the South
Carolina Department of Revenue or Secretary of State to avoid the withholding of
two percent (2%) of each payment made to the nonresident contractor.

 

ARTICLE
27 – DISPUTE RESOLUTION

 

27.1                           Claims.  A “Claim” is
any claim, dispute or other controversy arising out of or relating to this
Agreement, including Change Disputes. 
Claims must be initiated by written notice.  The responsibility to substantiate Claims
shall rest with the Party making the Claim. The

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-94-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

other Party shall provide reasonable cooperation in making
available non privileged information in its possession or control that is
relevant for purposes of substantiating the Claim.

 

27.2                           Change Dispute. 
A Party shall provide written notice to the other Party of any dispute
or disagreement that such Party may have regarding a request for a Change or a
notice of a Change given by either Party (“Change Dispute”), which notice shall
contain such Party’s position with respect to such Change Dispute (the “Change
Dispute Notice”).  Such Party shall
provide the Change Dispute Notice to the other Party no earlier than fifteen
(15) Days after such Party (a) submitted a notice of Change without having
received either (i) a written response from the other Party or (ii) a
response from the other Party regarding a notice of Change that is
unsatisfactory to such Party or (b), in the case of Section 9.2,
Contractor has received from Owner a request for a Change that Contractor does
not believe conforms to the requirements of Section 9.2, or a dispute
otherwise arises out of Section 9.2.

 

27.3                           Resolution by Negotiation.

 

(a)                                  As an express condition precedent to
commencement of any further proceedings with respect to a Claim (except as may
be provided under any applicable lien statute), the Party making such Claim
shall notify the other Party’s Project Director in writing of such Claim.  The Contractor’s Project Director and the
Owner’s Project Director shall meet within thirty (30) Days of receipt of the
written notice of such Claim for the purpose of attempting to resolve the
Claim.

 

(b)                                 If, after the Contractor’s Project
Director and the Owner’s Project Director meet, the Claim remains unresolved or
if no such meeting takes place for any reason within such thirty (30) Day
period, then an executive vice president (or equivalent) of (i), in the case of
Contractor, each Consortium Member (unless otherwise agreed by the Consortium
Members) and (ii), in the case of Owner, each of SCE&G and Santee Cooper
(unless otherwise agreed by them) shall meet to attempt to resolve such Claim,
as applicable, within fifteen (15) Days from the end of such thirty (30) Day
period.

 

(c)                                  If the Claim remains unresolved after the
fifteen (15) Day period described in Section 27.3(b) and the Parties
have not mutually agreed in writing to mediate such Claim, then:

 

(i)                                     with respect to a Claim that exceeds the
Threshold Amount, either Party shall have the right to proceed to litigation of
such Claim in a court of competent jurisdiction pursuant to Section 27.7;
and

 

(ii)                                  with respect to a Claim that meets or
falls below the Threshold Amount, such Claim shall be resolved pursuant to
Section 27.5.

 

(d)                                 The Parties agree to make a diligent,
good faith attempt to resolve a Claim as expeditiously as reasonably possible
as provided in this Section 27.3.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-95-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

27.4         Mediation.

 

(a)           The
Parties may mutually agree in writing to endeavor to resolve a Claim by
mediation which, unless the Parties mutually agree otherwise, shall be in
accordance with the Construction Industry Mediation Procedures of the AAA in
effect at the time of the mediation.  A
request for mediation shall be mutually filed in writing by the Parties with
the AAA.  If the mediation has not
concluded within sixty (60) Days after its commencement, then, as applicable:

 

(i)            with
respect to a Claim that exceeds the Threshold Amount, either Party shall have
the right to proceed to litigation of such Claim in a court of competent
jurisdiction pursuant to Section 27.7; and

 

(ii)           with
respect to a Claim that meets or falls below the Threshold Amount, such Claim
shall be resolved pursuant to Section 27.5.

 

(b)           The
Parties shall share the mediator’s fee and any AAA filing fees equally.  The mediation shall be held in Charlotte,
North Carolina, unless another location is mutually agreed upon. Agreements
reached in mediation shall be enforceable as settlement agreements pursuant to Section 27.7.

 

27.5         Arbitration of Claims Falling Below
the Threshold Amount.

 

(a)           The
Parties agree that any Claim meeting or falling below the Threshold Amount (“Arbitrable
Claim”) that is not resolved pursuant to Section 27.3 or 27.4 shall be
submitted to final and binding arbitration for resolution pursuant to this Section 27.5
and in accordance with the Construction Industry Arbitration Rules of the
AAA in effect at the time of the arbitration, except as modified by this Section 27.5
or otherwise agreed by the Parties.

 

(b)           Unless
the Parties otherwise mutually agree in writing, the arbitral panel (“Arbitral
Panel”) shall consist of three (3) people. 
Within ten (10) Days after the expiration of the fifteen (15) Day
period described in Section 27.3(b), each
Party shall give written notice of its selection of a person to serve as a
member of the Arbitral Panel (“Member”), who shall have no less than ten (10) years
of experience in the litigation of complex disputes including preferably
experience in the power plant construction industry.  If a Party fails to notify the other Party of
the selection of its Member within such fifteen (15) Day period, then such
Member shall be appointed by the AAA. 
Within thirty (30) Days after the selection of the Members of the
Arbitral Panel, the Members shall mutually agree in writing on their nomination
of two (2) persons to serve as the chairman of the Arbitral Panel, who
shall be practicing attorneys validly licensed to practice law in a
jurisdiction in the United States and/or retired judges, and who shall have no
less than twenty (20) years of experience in the litigation of complex disputes
including preferably experience in the power plant construction industry (the “Chairman”).  (References herein to “Member” shall include
the Chairman unless the context otherwise requires.)  The Members shall then select one of such
nominated persons to serve as the Chairman. 
In the event that the Members do not mutually agree on the person to
serve as the Chairman within such thirty (30) Day period, each Member shall
submit its nominated person to AAA, and the AAA shall decide the nominee to
serve as the Chairman.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-96-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

(c)           It being imperative that all Members of the Arbitral
Panel be neutral, act impartially, and be free from any conflict of interest,
the Parties shall select such persons on the basis that the Members and the
Chairman shall:

 

(i)            have no interest financial or otherwise in either Party
nor any financial interest in this Agreement except for payment of its fees and
expenses as provided herein;

 

(ii)           not previously have been employed as a consultant or
otherwise by either Party, unless any such relationship has been disclosed in
writing and approved by the Parties;

 

(iii)          have disclosed in writing to the Parties and each other
Member and the Chairman as applicable, before being selected and to his or her
best knowledge and recollection, any professional or personal relationships
with any director, officer or employee of either Party;

 

(iv)          not, for the duration of the Arbitral Panel, be employed as
a consultant or otherwise by either Party, except as may be agreed in writing
by the Parties, the other Members and the Chairman;

 

(v)           not give advice to either Party or its Personnel
concerning the conduct of this Agreement, other than in accordance with this
Agreement;

 

(vi)          not have any ex-parte communications with either Party at
any time after their selection pursuant to Section 27.5(b);

 

(vii)         not, while a Member or Chairman, as applicable, enter into
discussions or make any agreement with either Party regarding employment by any
of them, whether as a consultant or otherwise, after ceasing to act as a Member
or Chairman, as applicable; and

 

(viii)        treat the details of this Agreement and all the Arbitral
Panel’s activities and hearings as private and confidential, and not publish or
disclose them without the prior written consent of the Parties.

 

(d)           Each
Party shall be responsible for one-half of the fees and expenses of the
Arbitral Panel, unless the Arbitral Panel includes an award of fees and
expenses in the award.  Contractor shall
not include such fees and expenses in any amounts invoiced to Owner under this
Agreement.

 

(e)           Either
Party shall be entitled to have any third party join into any proceedings
hereunder as a party thereto under this Section 27.5.  A Party may fully defend against any
proceedings hereunder, provided that a Party shall not be entitled to make a
counterclaim against the other Party unless the counterclaim arises out of the
occurrence that is the subject of the pending Arbitrable Claim.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-97-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

(f)            The
Arbitral Panel shall be governed by the provisions of this Agreement and the
governing Law, and shall not be entitled to award any punitive, special,
indirect, penal, incidental or consequential loss or damages.

 

(g)           The
Parties shall promptly provide the Arbitral Panel with such additional
information and access to such facilities and Personnel as the Arbitral Panel
may require for purposes of resolving any submitted Arbitrable Claim.  The Arbitral Panel shall use reasonable
efforts to resolve any submitted Arbitrable Claim as promptly as reasonably
practicable and in any event within sixty (60) Days of the appointment of the
Chairman of an Arbitral Panel where the amount in controversy is less than [**]
(per claim for monetary relief) or where a schedule dispute (per Contractor
claim for schedule relief) is less than thirty (30) Days, or within one hundred
eighty (180) Days of the appointment of the Chairman of an Arbitral Panel (or
such other number of Days as may be proposed by the Arbitral Panel and accepted
by both Parties (which acceptance shall not be unreasonably withheld)) where
the amount in controversy is [**] (per claim for monetary relief) or more or
where the schedule dispute (per Contractor claim for schedule relief) is thirty
(30) Days or more.  Notwithstanding the
foregoing, if the Parties mutually agree to a deadline extension or the
Chairman determines that it is not feasible to resolve the Arbitrable Claim
within the above listed deadlines, then a deadline may be extended to provide
additional time to resolve such Arbitrable Claim; provided, that the duration
of any such extension shall be set taking into account the agreed upon principle
that disputes are to be resolved as expeditiously as possible.  The Parties expressly agree that the Arbitral
Panel shall have no power to consider or award any form of damages or remedies
barred by this Agreement.

 

(h)           The
decision of the Arbitral Panel shall be issued in a writing that sets forth the
Arbitral Panel’s reasoned decision.  The
Arbitral Panel shall not be entitled to deviate from the construct, procedures
or requirements of this Agreement. In the absence of bias, fraud, or willful
misconduct by an arbitrator, any decision rendered by the Arbitral Panel in any
arbitration shall be final and binding upon the Parties under the United States
Arbitration Act 9 U.S.C. §§ 1 et  seq., and judgment thereon may
be entered in the court described in Section 27.7.

 

27.6         Exclusive Resolution Procedures;
Equitable Remedies.  The procedures
specified in this Article shall be the sole and exclusive procedures for
the resolution of Claims (except for lien claims which are governed by
statute); provided, however, that, notwithstanding anything in this Article to
the contrary, a Party may file a complaint in the court described in Section 27.7
to seek injunctive relief, sequestration, garnishment, attachment, or an
appointment of a receiver.  Despite such
actions, the Parties shall continue to participate in good faith in and be
bound by the dispute resolution procedures specified in this Article.

 

27.7         Consent to Jurisdiction.  The Parties agree to the exclusive
jurisdiction of the United States District Court for the Southern District of
New York or, if such court does not have jurisdiction of the matter, the courts
of the State of New York located in the City and County of New York, for any
legal proceedings that may be brought by a Party arising out of or in connection
with this Agreement or for
recognition or enforcement of any judgment or settlement agreement.  By execution and delivery of this Agreement,
each Party accepts, generally and

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-98-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

unconditionally, the jurisdiction of the aforesaid
court for legal proceedings arising out of or in connection with this
Agreement.  Each Party hereby waives any
right to stay or dismiss any action or proceeding under or in connection with
this Agreement brought before the foregoing court on the basis of forum
non-conveniens or improper venue.

 

27.8         Continuation of Work.  Pending the final resolution of any Claim,
Contractor shall proceed diligently with the performance or provision of the
Work and its other duties and obligations and Owner shall continue to
compensate Contractor as set forth under this Agreement without diminution of
effort; provided that Contractor is being compensated for the Work pursuant to
the terms of this Agreement, including but not limited to the provisions of Article 8
and provided that the Parties agree that such duties and obligations can be
safely and prudently performed.

 

ARTICLE
28 — NOTICES

 

All notices, communications, and approvals required or
permitted to be given hereunder shall be in writing and shall be valid and
sufficient if delivered in person or dispatched by certified mail (return
receipt requested), postage prepaid, in any post office in the United States or
by any national overnight express mail services (return receipt requested), and
addressed as follows:

 

If to Owner:

 

South Carolina Electric &
Gas Company

Attn: President

Mail Code 190

Columbia, SC 29218

Telephone No.:
803-217-8097 

Facsimile No.:
803-217-9336

 

South Carolina Public
Service Authority

Attn: Chief Operating
Officer (M602)

One Riverwood Drive

P.O. Box 2946101

Moncks Corner, SC
29461-6101

Telephone No.:
843-761-4087

Facsimile No.:
843-761-7037

 

With a copy to:

 

South Carolina Electric &
Gas Company

Attn: General Counsel

Mail Code 190

Columbia, SC 29218

Telephone No.:
803-217-8634 

Facsimile No.:
803-217-9336

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-99-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

South Carolina Public
Service Authority

Attn: General Counsel
(M603)

One Riverwood Drive

P.O. Box 2946101

Moncks Corner, SC
29461-6101

Telephone No.:
843-761-7007

Facsimile No.:
843-761-7037

 

If to Westinghouse:

 

Westinghouse Electric
Company, LLC

Attn:  Daniel Lipman

4350 Northern Pike

Monroeville, PA 15146

Telephone No.: (412)
374-6920

Facsimile No.: (412)
374-6677

 

With a copy to:

 

Westinghouse Electric
Company, LLC

Attn:  General Counsel

4350 Northern Pike

Monroeville, PA 15146

Telephone No.: (412)
374-6177

Facsimile No.: (412)
374-6122

 

If to Stone & Webster:

 

Stone & Webster, Inc.

Attn:  Ed Hubner

3 Executive Campus

Cherry Hill, NJ 08002

Telephone No.: (856)
482-4178

Facsimile No.: (856)
482-3155

 

with a copy to:

 

Stone & Webster, Inc.

Attn:  E.K. Jenkins

E&C Division Counsel

100 Technology Center
Drive

Stoughton, MA 02072

Facsimile No.: (617)
589-1322

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-100-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

or to such other address, attention or facsimile
number as such Party to whom such notice is to be addressed shall have
hereafter furnished to the other Party in writing as provided in this Article.

 

Notwithstanding the foregoing, any routine
correspondence (as further defined in the Project Execution Plan) shall be sent
to the appropriate project management and personnel that may be agreed upon by
the Parties. Copies of such routine correspondence shall not be routed to the
persons listed above.

 

ARTICLE
29 — ASSIGNMENT

 

Neither Party shall assign this Agreement in whole or
in part without the prior written consent of the other Party.  If any assignment by any Party of this
Agreement or any right, interest or obligation therein requires the consent of,
or notice to, any Government Authority, including the NRC, then such Party
shall not effect such assignment without such consent of, or notice to, such
Government Authority.

 

ARTICLE
30 — WAIVER

 

The failure of either Party to enforce at any time any
of the provisions of this Agreement shall not be construed as a waiver of such
provision nor shall not in any way affect the validity of this Agreement or the
right of either Party to enforce each and every provision.

 

ARTICLE
31 — MODIFICATION

 

No waiver, modification, or amendment of any of the
provisions of this Agreement shall be binding unless it is in writing and
signed by duly authorized representatives of both Parties.

 

ARTICLE
32 — SURVIVAL

 

The Parties agree that the provisions of Article 15
— Indemnity, Article 17 — Limitation of Liability, Article 19 —
Proprietary Data, Article 27 — Dispute Resolution, Section 22.2(e) —
[**], and Section 25.4 —Right to Audit, this Article and any other
terms and conditions of this Agreement that are expressly stated to survive or
limiting the liability of Contractor shall survive termination, cancellation or
expiration of this Agreement. Any liability and insurance protections afforded
a Party hereunder shall apply during the Work and thereafter, and shall survive
termination, cancellation or expiration of this Agreement, subject to time
limitations provided for in this Agreement.

 

ARTICLE
33 — TRANSFER

 

Prior to the removal of any Equipment furnished hereunder
from the Facility, except temporarily for repair or permanently for disposal,
Owner shall provide Contractor with written assurances from the transferee of
limitation of and protection against liability following the proposed removal
or transfer at least equivalent to that afforded Contractor and Contractor
Interests under the provisions of this Agreement. Removal or transfer contrary
to the provisions of this Article shall, in addition to any other legal or
equitable rights of Contractor, make Owner the indemnitor

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-101-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

of Contractor and Contractor Interests against any
liabilities incurred by Contractor and Contractor Interests in excess of those
that would have been incurred had no such transfer taken place.

 

ARTICLE
34 — GOVERNING LAW; WAIVER OF JURY TRIAL; CERTAIN FEDERAL LAWS

 

34.1         Governing Law.  The validity, construction, and performance
of this Agreement shall be governed by and interpreted in accordance with the
laws of the State of New York, without giving effect to the principles thereof
relating to conflicts of laws except Section 5-1401 of the New York
General Obligations Law; provided, however, that nothing in this Agreement
shall seek to alter the rights, responsibilities and limitations applicable to
Santee Cooper under the laws of the State of South Carolina.

 

34.2         Waiver of Jury Trial.  EACH PARTY HEREBY IRREVOCABLY WAIVES ALL
RIGHT TO TRIAL BY JURY IN ANY ACTION, PROCEEDING OR COUNTERCLAIM (WHETHER BASED
ON CONTRACT, TORT OR OTHERWISE) ARISING OUT OF OR RELATING TO THIS AGREEMENT.

 

34.3         Certain Federal Laws.  In the performance of Work under this
Agreement, Contractor and its Subcontractors shall comply with applicable Law,
including provisions of Executive Order 11246, as amended, relating to equal
opportunity and nonsegregated facilities, the Fair Labor Standards Act of 1933,
the Occupational Safety and Health Act of 1970, and the requirements of the
rules, regulations, orders, bulletins and interpretations of the NRC, and with
the Laws as set forth in Exhibit S, to the extent applicable to
Contractor or Subcontractors. Contractor further agrees to comply with, and
agrees to require Subcontractors that are subject to such requirements to
comply with, Owner’s Government Contracting Programs requirements as specified
in 13 CFR 125, 48 CFR 52.219-8, and 48 CFR 52.219-9.

 

ARTICLE
35 — RELATIONSHIP OF OWNER AND CONTRACTOR

 

Contractor is an independent contractor and nothing
contained herein shall be construed as creating (i) any relationship
between Owner and Contractor other than that of owner and independent
contractor, (ii) any relationship whatsoever between Owner and Contractor’s
employees or Subcontractors or (iii) a fiduciary relationship between
Contractor and Owner.  Neither
Contractor, nor any of its employees, are or shall be deemed to be employees of
Owner.

 

ARTICLE
36 — THIRD PARTY BENEFICIARIES

 

Except as expressly set forth in this Agreement, the
provisions of this Agreement are intended for the sole benefit of Owner and
Contractor and each Consortium Member, and the Parties do not intend to create
any other third party beneficiaries or otherwise create privity of contract
with any other Person.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-102-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

ARTICLE
37 — REPRESENTATIONS AND WARRANTIES

 

37.1         Representations and Warranties of
Contractor.  Each Consortium Member
hereby represents and warrants to Owner as follows:

 

(a)           Due
Organization of Consortium Member.

 

(i)            Stone &
Webster represents and warrants that it is duly organized, validly existing and
in good standing under the laws of the State of Louisiana and has the requisite
power and authority to own and operate its business and properties and to carry
on its business as such business is now being conducted and is duly qualified
to do business in the State of South Carolina and in any other jurisdiction in
which the transaction of its business makes such qualification necessary.

 

(ii)           Westinghouse
represents and warrants that it is duly organized, validly existing and in good
standing under the laws of the State of Delaware and has the requisite power
and authority to own and operate its business and properties and to carry on
its business as such business is now being conducted and is duly qualified to
do business in the State of South Carolina and in any other jurisdiction in
which the transaction of its business makes such qualification necessary.

 

(b)           Due
Authorization of Consortium Member; Binding Obligation.  Consortium Member has full power and
authority to execute and deliver this Agreement and to perform its obligations
hereunder, and the execution, delivery and performance of this Agreement by
Consortium Member has been duly authorized by the necessary action on the part of
such Consortium Member; this Agreement has been duly executed and delivered by
such Consortium Member and is the valid and binding obligation of such
Consortium Member enforceable in accordance with its terms.

 

(c)           Non-Contravention.  The execution, delivery and performance of
this Agreement by Consortium Member and the consummation of the transactions
contemplated hereby do not and shall not contravene any applicable Law or the
organizational documents of such Consortium Member and do not and shall not conflict
with or result in a breach of or default under any indenture, mortgage, lease,
agreement, instrument, judgment, decree, order or ruling to which such
Consortium Member is a party or by which it or any of its properties is bound
or affected.

 

(d)           Consortium
Agreement. The Consortium Members have entered into an agreement setting
forth their consortium arrangements for the performance of this Agreement and
their sharing of liabilities with respect thereto.

 

37.2         Representations and Warranties of
SCE&G and Santee Cooper.  Each of
SCE&G and Santee Cooper hereby represents, warrants and covenants to
Contractor as follows:

 

(a)           Due
Organization of Owner.  It is duly
organized, validly existing and in good standing under the laws of the State of
South Carolina and has the requisite power and authority to own and operate its
business and properties and to carry on its business as such

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-103-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

business is now being
conducted and is duly qualified to do business in State of South Carolina and
in any other jurisdiction in which the transaction of its business makes such
qualification necessary.

 

(b)           Due
Authorization of Owner; Binding Obligation. 
Its execution, delivery and performance of this Agreement has been duly
and effectively authorized by the requisite action on the part of its governing
board.  This Agreement constitutes its
legal, valid and binding obligations, enforceable against it in accordance with
its terms, except as limited by applicable bankruptcy, insolvency,
reorganization, moratorium or other Laws affecting the rights of creditors
generally and by general principles of equity.

 

(c)           Non-Contravention.  Its execution, delivery and performance of
this Agreement and the consummation of the transactions contemplated hereby do
not and shall not contravene any applicable Law or organizational documents or
do not and shall not conflict with or result in a breach of or default under
any indenture, mortgage, lease, agreement, instrument, judgment, decree, order
or ruling to which it is a party or by which it or any of its properties is
bound or affected.

 

On the Effective Date, Santee Cooper shall provide a
letter to Contractor making each of the representations set forth in this Section 37.2
on its own behalf as well as a representation that Santee Cooper has appointed
SCE&G as its agent pursuant to the Limited Agency Agreement, which is
attached hereto Exhibit V, for all purposes under this Agreement,
with the power and authority to bind Santee Cooper to its obligations herein,
subject to the limitations specifically set forth in the Limited Agency
Agreement.  In such letter, Santee Cooper
shall also agree to notify Contractor promptly in writing if there is any
change in the limits of SCE&G’s authority set forth in such Limited Agency
Agreement.

 

ARTICLE
38 — MISCELLANEOUS PROVISIONS

 

38.1         Rights Exclusive.  The rights and remedies of Owner or
Contractor as set forth in this Agreement shall be the exclusive rights or
remedies of the Parties. The limitations of liability, waivers, indemnities,
extension of insurances and other liability protection provided herein for the
benefit of Contractor shall also apply for the benefit of Contractor Interests
and shall apply irrespective of the basis of such claim, whether arising at
contract (including breach warranty, indemnity, etc.), tort or otherwise, and
regardless of fault, negligence or strict liability.

 

38.2         Severability.  If any provision of this Agreement or the
application of this Agreement to any Person or circumstance shall to any extent
be held invalid or unenforceable by a court of competent jurisdiction or
arbitrator under Article 27, then (i) the remainder of this Agreement
and the application of that provision to Persons or circumstances other than
those as to which it is specifically held invalid or unenforceable shall not be
affected, and every remaining provision of this Agreement shall be valid and
binding to the fullest extent permitted by Laws, and (ii) a suitable and
equitable provision shall be substituted for such invalid or unenforceable
provision in order to carry out, so far as may be valid and enforceable, the
intent and purpose of such invalid or unenforceable provision.

 

“[**]” in this Exhibit 10.01 indicates material
that has been omitted pursuant to a request for confidential treatment and
filed separately with the Securities and Exchange Commission.

 

-104-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

38.3         Entire Agreement.  This Agreement contains the entire agreement
and understanding between the parties as to the subject matter of this
Agreement, and merges and supersedes all prior agreements, commitments,
representations, writings and discussions between them other than the Existing
Confidentiality Agreement, which shall remain in effect for the purposes set
forth in Section 19.2(c)(i). Neither of the Parties shall be bound by any
prior obligations, conditions, warranties, or representations with respect to
the subject matter of this Agreement.

 

38.4         Counterparts.  This Agreement may be executed in two or more
counterparts, each of which shall be deemed an original, but all of which
together shall constitute one and the same instrument.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-105-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

IN
WITNESS WHEREOF,
the Parties have duly executed this Agreement as of the date first above
written.

 

 

	
  SOUTH CAROLINA ELECTRIC & GAS COMPANY, 

  	
   

  	
   

  
	
  for itself and as agent for South Carolina Public
  Service Authority

  	
   

  	
   

  
	
  By:

  	
  /s/ William B. Timmerman

  	
   

  	
   

  
	
  Name:

  	
  William B. Timmerman

  	
   

  	
   

  
	
  Title:

  	
  President and CEO

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  STONE & WEBSTER, INC.

  	
   

  	
  WESTINGHOUSE ELECTRIC COMPANY LLC

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  By:

  	
  /s/ David P. Barry

  	
   

  	
  By:

  	
  /s/ Aris Candris

  
	
  Name:

  	
  David P. Barry

  	
   

  	
  Name:

  	
  Aris Candris

  
	
  Title:

  	
  Executive Vice President

  	
   

  	
  Title:

  	
  Senior Vice President

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

-106-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT A

Scope of Work / Supply

And Division of Responsibility

 

Capitalized
terms used herein and not otherwise defined herein have the meanings assigned
to such terms in the Agreement to which this Exhibit A is appended.

 

A.1          Phase I

 

Phase
I of the Work will consist of [**].  The
Work in Phase I will also include the project initiation activities necessary
to execute the entire Scope of Work and the project activities necessary prior
to Full Notice to Proceed.  Phase I will
include any construction mobilization, Site preparation and development, and
other activities authorized by Owner prior to Full Notice to Proceed.  As such, Contractor’s organization will be
established as the project develops and will grow as necessary to execute the
Phase I activities for a smooth transition into Phase II following Full Notice
to Proceed.

 

The
activity descriptions associated with Phase I are provided below.  The initial functional project staffing for
Phase I of the Work will be a subset of the project organization provided in Exhibit B.  Through Phase I the organization will grow as
required to be fully staffed at Full Notice to Proceed.

 

A.1.1       Project Management and Administration

 

The
project management Work scope includes the management of all ongoing activities
during the Phase I effort and to facilitate the transition for performance of
the Work to Full Notice to Proceed. 
Phase I of the Work includes:

 

·                  Project management and
overall guidance and direction of all Work;

·                  Preparation of the project
specific Quality Assurance Program and project specific procedures to implement
the Agreement;

·                  Preparation of the
integrated Project Schedule and monitoring of task plans, for the Scope of
Work;

·                  [**]

·                  [**]

·                  Coordination of the
Information Management System (as defined in A.1.3.) interface and document
control activities;

·                  Primary Owner interface
between Westinghouse and Stone & Webster;

·                  Monthly consolidated
(Contractor) project status reports;

·                  Monthly status review
meetings;

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
1 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

·                  Project controls;

·                  Contract administration; and

·                  Administrative and clerical
support for project activities.

 

Contractor’s
Project Director will provide oversight of all project activities.  Stone & Webster will be performing
Site specific activities including development of Site specific inputs to the
Project Schedule, preliminary and detailed engineering, preliminary design to
integrate and convert Site temporary facilities during construction to
permanent facilities, and Site geotechnical review to assess design and
construction.  Construction planning
activities will be conducted for Site transportation and logistics, and Site
excavation.

 

An
integrated Project Schedule will be used to coordinate activities and
interfaces during the engineering, procurement and construction
activities.  The project organization
will develop a Level 1 master procurement and construction schedule in
consultation with Owner. The Project Schedule will state the engineering
schedule required to support the procurement and construction schedule.

 

A
core project management team will be established for developing and
administering controls and processes for the AP1000 Nuclear Power Plant
(herein, the “AP1000” or “AP1000 Plant”) engineering, procurement and
construction.  The team will be built
during Phase I.  The project organization
is shown in Exhibit B.  Utilizing
this core team for support, a dedicated individual referred to as Contractor’s
Project Director will execute the project activities to complete Site specific
engineering, perform initial procurement and prepare the Site for construction.

 

A.1.2                    Supply Chain
Management

 

Contractor
will provide services pertaining to early procurement activities necessary for
support of the Project Schedule.  Long
lead items will be identified and ordered in advance of the Full Notice to
Proceed, to properly support the Project Schedule.  Project personnel will be assigned to ensure
the supply of the key and critical plant equipment will accommodate the
schedule requirements.  These persons may
be shared resources with other projects.

 

The
early procurement activities will include, but not be limited to, the following
Equipment:

 

1.                                       [**];

2.                                       [**];

3.                                       [**];

4.                                       [**];

5.                                       [**];

6.                                       [**];

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
2 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

7.                                       [**];

8.                                       [**];

9.                                       [**]; and

10.                                 [**].

 

In
addition to the procurement activities for the Equipment identified above, the
other equipment that is required for the AP1000 will need to be evaluated for
what is required, when it is needed in the schedule, and where it is needed.

 

Supply
chain management will provide the following services:

 

·                  Identify the
existing suppliers comprising the supply base.

·                  [**]

·                  [**]

·                  [**]

·                  Identify
procurement items that are required to support agreed upon schedule and develop
a supply plan linked to the schedule.

·                  Evaluate
supplier bids, terms and conditions negotiated, and purchase orders executed in
support of long lead procurement.

·                  [**]

·                  Request
engineering to assist or evaluate requirements from Equipment suppliers during
fabrication as needed.

·                  [**]

·                  [**]

·                  Conduct initial
kick-off meetings with selected suppliers to assure all requirements are
understood and suppliers are ready to implement appropriately.

·                  Participate in
periodic supplier meetings with long lead material sub-suppliers to assure
requirements are understood and are being implemented consistent with order
requirements.

·                  Provide
frequent follow-up and communications with suppliers to ensure progress
consistent with plan and schedule.

·                  Identify supply
issues and execute timely corrective action when required.

·                  Provide supply
status to the project team.

·                  Plan and
coordinate logistics and transportation for delivery to the Site.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
3 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Engineering

 

In
support of supply chain management, the following engineering services will be
provided:

 

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

 

Quality
Assurance

 

In
support of supply chain management, the following quality engineering services
will be provided:

 

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
4 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

 

A.1.3                              Information Management
System

 

An
information management system (“Information Management System”) will be
developed to store AP1000 information related to the Facility.  This system will provide the following:

 

·                  [**]

·                  [**]

·                  [**]

·                  [**]

 

A.1.4                              Module Management

 

A
module management plan will document the detailed work to be accomplished going
forward to ensure the efficient completion of module planning, procurement,
delivery, storage, Site assembly, outfitting and installation.  A list of structural modules and mechanical
modules for the AP1000 Plant will be defined.

 

The
integrated schedule will be reviewed to examine the complete schedule logic for
each individual module associated with the AP1000 Plant.  A backward-pass through the schedule will be
performed “starting” with the module installation date. Working backward, the
logic and durations will be examined and independently confirmed to the current
design status.  A priority will be
established for the modules based upon:

 

·                  Early installation in the
plant.

·                  High degree of complexity
(e.g., containing multiple types of Equipment or commodities).

·                  Modules that contain long
lead Equipment.

·                  Modules that are assembled
on Site from sub-assemblies.

 

Module
fabrication planning will be conducted with selected suppliers determined to
possess the requisite technical expertise, facilities, quality and commercial
capabilities to assist in the design of modules and to supply modules for the
AP1000.  Following this

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
5 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

planning,
the procurement, fabrication, delivery and on Site construction activities will
be defined in the Project Schedule.

 

A.1.5                              Site Specific Scope

 

Phase
I of the Work includes Site specific (non-NuStart) design and Site development
activities prior to AP1000 construction. The Site specific activities will
include development of the Project Schedule, preliminary and detailed
engineering, scheduling, preliminary design to integrate and convert Site
temporary facilities during construction to permanent facilities, and Site
geotechnical review to assess design and construction. Construction planning
activities will be conducted for Site transportation and logistics, and Site
excavation.  Mobilization of construction
and Site preparation and development activities will be performed as necessary
to meet schedule.

 

A.1.5.1                     Preliminary Site Specific
Engineering

 

The
preliminary Site specific engineering includes the engineering required to
define layout, quantities, sizes and costs for the Site and Owner-specific aspects
of the design.  [**]  This work is to include:

 

·                  Evaluation of the Site or
review of existing evaluations for development of design criteria for Site
specific systems, structures and components including those that contain
undergrounds (circ water, fire loop, underground duct banks, storm drains,
waste water, potable water, tanks with underground piping, sanitary sewage,
cathodic protection);

·                  Preparation of conceptual
designs;

·                  Development of dimensioned
layout drawings and preliminary foundation cross-sections;

·                  System and component sizing
calculations which support conceptual designs;

·                  Key Equipment and component
specifications for conceptual designs;

·                  Preparation of P&ID’s
which support conceptual designs;

·                  Preparation of preliminary
structural drawing information to define structural commodities;

·                  Preparation of preliminary
piping drawings for large bore piping for quantity assessments;

·                  Electrical one-line drawings
for conceptual designs;

·                  Control logics;

·                  Preparation of bid packages for
key components;

·                  Bid evaluations and vendor
selection for most key components; and

·                  Review of vendor design
packages.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
6 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

A.1.5.2                     Detailed Site Specific
Engineering

 

The
detailed Site specific engineering includes that portion of the Site specific
engineering that is required to be complete to support the start of
pre-construction and construction activities. This work is to include:

 

·                  Completion of Site
preparation plans, Site layout and initial Site grubbing/ grading
plans/excavation;

·                  Completion of engineering
for underground systems and other systems required to support construction;

·                  Completion of engineering to
support module development based on the module and procurement lead times;

·                  Completion of engineering
for Equipment and commodities to support procurement of long lead time items
needed to support installation schedule requirements;

·                  Site heavy haul load
evaluations, engineering of haul foundations, hardstands for cranes, module
erection pad foundations;

·                  Site infrastructure design
including all roads(Parr road, construction access road, Facility access road,
discharge structure road, switchyard road, Hwy 213 intersection warehouse
receiving road, etc), rail, construction water, construction fire protection
and construction power; and

·                  Development of
specifications and procurement of systems and commodities to support
construction: underground commodities for undergrounds; water treatment
facilities, batch plant; temporary electrical power design and components and
other items identified in the construction execution plan.

 

A.1.5.3                     AP1000 Envelope Evaluation

 

The
scope of this package is to perform an assessment of Site specific parameters
and to identify any work scope impacts associated with siting the standard
design and establishing the design criteria for the Site specific design. This
work to include the assessment of:

 

·                  Site meteorological
parameters;

·                  [**]

·                  Site soil and rock
properties;

·                  Site groundwater conditions;

·                  Water supply properties;

·                  State and local Laws and
required Government Approvals;

·                  Impacts of nearby
facilities/utilities;

·                  Site flood history; and

·                  Soil stabilization
techniques.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
7 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

A.1.5.4                     Site Geotechnical Review - Design Assessment

 

The
scope of this package is to perform an assessment of the Site specific geotechnical
parameters based on data collected by Owner and Contractor.  The impacts on the standard design and the
design criteria for the Site specific design will be defined. This work shall
include:

 

·                  Assessment of Site soil and
rock properties, including dynamic properties and load bearing capacities;

·                  [**]

·                  Assessment of Site
groundwater conditions: design bases for hydrostatic pressure and dewatering of
excavations;

·                  Assessment of the adequacy of
existing information and identification of any additional information; and

·                  Development of related
construction requirements, guidelines, and plans.

 

A.1.5.5                     Regional Infrastructure
Assessment

 

The
scope is to perform an assessment of the infrastructure required to support the
construction of an AP1000 Nuclear Power Plant and to define the impacts on
construction, modularization and the ability to transport fabrications to the
Site. This work shall include:

 

·                  Railroad access;

 

·                  Highway road access;

 

·                  Available utilities
(water/sewage/ power);

 

·                  Medical facilities;

 

·                  Fire fighting facilities;

 

·                  Available housing;

 

·                  Schools;

 

·                  Financial facilities;

 

·                  Regional communications;

 

·                  Local governments; and

 

·                  News outlets.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
8 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

A.1.5.6                     Project Specific Equipment & Material Logistics Deployment Model
(including Transportation and Logistics Plan)

 

The
scope of this activity identifies attributes to be evaluated and develops plans
for the transportation of heavy equipment and modules. Input for this task
includes the results of the evaluations performed as part of the regional
assessment. This task defines the following:

 

·                  Module / large components
shipping routes;

·                  Highway capability
(material/module shipments);

·                  Waterway / barge
availability (material/module shipments);

·                  Bridge capacities
(material/module shipments);

·                  Overhead electrical
(shipping routes);

·                  Heavy haulers / cranes; and

·                  Railroad capabilities.

 

A.1.5.7                     Site Specific Procurement Plan

 

The
scope of work for this area will include the investigation and development of
Site specific changes to the specifications for the Standard Plant needed to
reflect Site specific and Owner requirements for the purchase of Equipment and
commodities and to tailor procedures to reflect these requirements. This work
shall include:

 

·                  Site description;

·                  Site transportation
information;

·                  Owner specific contract
requirements;

·                  Site security restrictions;

·                  Site access restrictions;

·                  Site prohibitions;

·                  Special environmental
requirements; and

·                  Special state and local
Laws.

 

A.1.5.8                     Local Labor Survey

 

The
scope of this survey is to perform an assessment of craft availability and
training requirement needed to support the construction of the AP1000 Nuclear
Power Plant.

 

Evaluate
craft availability (all crafts)

 

·                  Dedicate a staffing team to
focus on nuclear talent;

·                  Establish initial resource
profile by discipline;

·                  [**]; and

·                  [**].

 

“[**]” in this Exhibit 10.01 indicates material
that has been omitted pursuant to a request for confidential treatment and
filed separately with the Securities and Exchange Commission.

 

Page
9 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Evaluate Craft
training/qualifications

 

·                  [**];

·                  [**];

·                  [**]; and

·                  [**]

·                  [**].

·                  [**]

·                  [**].

·                  [**].

 

A.1.5.9                     Local Subcontractor Evaluations & Agreements

 

The
work under this task identifies specific needs as related to Subcontractor
requirements.

 

·                  Prefabrication

·                  Modularization

·                  Area and specialty
contractors (e.g., painting, HVAC, fire protection)

·                  Emergency health care

·                  Consumable tools/materials

 

Specific
Subcontractors will be identified. Evaluations of their capabilities will be
performed and contracts will be negotiated with selected contractors.

 

A.1.5.10               Environmental Management Plan

 

The
scope of this package is to perform an assessment of the Site specific
environmental information and data collected by Owner and define the impacts on
the standard design and the design criteria for the Site specific design. This
work to include:

 

·                  Water run-off;

·                  Erosion and Sedimentation
Control;

·                  Plant and animal data and
protection requirements;

·                  Wetlands requirements;

·                  Existing potential hazardous
materials;

·                  State and local regulations;

·                  Any other potential items
that could impact design or construction.

 

Based
on this assessment, requirements would be developed for the designers and
construction team to use in the work. These requirements would be incorporated
into the appropriate project procedures and used for the preparation of any
Government Approvals.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
10 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

A.1.5.11               Early Procurement/Vendor Commitments

 

The
work under this task includes the procurement support for turbine island and
Site specific and selected key components and commodities to support design
development and plant integrated schedule. This includes:

 

·                  Vendor identification;

·                  Performance of  needed surveys and reviews;

·                  Preparation of bid packages;

·                  Solicitation of bids;

·                  Bid evaluation and award;

·                  Vendor qualification and
audit; and

·                  Negotiation and contract
placement.

 

A.1.5.12     Level
2+ Site Specific Schedule

 

This
scope includes the development of the schedule for Site specific engineering,
procurement and construction activities and the integration of these activities
into the standard AP1000 schedule to yield the definite Project Schedule.

 

A.1.5.13    Project
Specific Construction Execution Plan (including construction schedule
enhancement initiatives - commitments; sustained installation plan)

 

This
activity includes the development of an integrated Site specific construction
schedule.

 

·                  Integrate Site specific
requirements into standard construction schedule (i.e., excavation, backfill
plan, yard layout, etc.)

 

A.1.5.14     Project
Organization and Structure-DOR Roles and Responsibilities

 

This
activity includes the development of the Site and Owner specific Work scope,
including identification of the necessary division of responsibility between
Owner and Contractor and the interfaces for Contractor to a level of detail
that is sufficient to serve as the bases for the Phase I Scope of Work as well
as the Work plan for Phase II.

 

A.1.5.15     Site
temporary facilities integration with permanent conversion (Design, Estimating,
Procurement)

 

The
scope of this package is to identify the needs for temporary structures /
facilities for a standard AP1000 construction site. This work shall include:

 

·                  Engineering facilities;

·                  Management facilities;

·                  Craft facilities;

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
11 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

·                  Safety facilities;

·                  Construction tool rooms;

·                  Construction material warehouses;

·                  Construction equipment storage and
maintenance facilities;

·                  Module laydown areas;

·                  Mechanical /electrical fabrication shop;

·                  Warehouses.

·                  Civil shop

·                  Repair shop (truck, equipment, fueling)

·                  Craft training facilities

·                  Water treatment facilities (temporary
and  permanent as applicable)

·                  Construction waste disposal facilities

 

A.1.5.16               Excavation plans
(including tie-back walls, Mechanically Stabilized Earth (MSE) walls) and yard
early construction before NI and TI as well as existing facilities

 

The
scope of this package is to perform an assessment of the Site specific soil
conditions and address any existing or new underground facilities existing that
have potential impacts on the standard design. 
This work shall include:

 

·                  Soil stabilization process;

·                  Waterproofing process/technique;

·                  Engineering for 100% of the underground
facilities;

·                  Locating existing underground facilities;

·                  Plan for the installation of new underground
facilities;

·                  Plan for completing the excavation and
installing utilities prior to start of construction;

·                  Investigate and plan for existing rock, i.e.,
blasting, removal and disposal; and

·                  As built documentation and location of all
installed underground facilities

 

A.1.5.17               Mockup and practice modules (typical for each category)

 

This
activity includes the implementation of the following aspects of the
modularization plan.

 

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page 12 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

A.1.5.18               Plan for the Initial Test Program

 

During
Phase I, Owner and Contractor will develop a detailed plan for the performance
of Preoperational and Startup Tests. 
This plan will include the minimum number of Owner and Contractor
personnel needed for the performance of this testing to support the Project
Schedule.  The Initial Test Program is
described in Section 3 of this Exhibit A.

 

A.1.5.19               Site Preparation and Development Activities

 

Prepare
work packages and perform initial Site preparation and development activities
in accordance with schedule and as allowed prior to Full Notice to Proceed
including:

 

·                  Railroad
modifications;

·                  Road
modifications;

·                  Clearing,
grubbing and grading;

·                  Erosion and
sediment control;

·                  Core borings
for buildings, road and railway work;

·                  Site surveying;

·                  Providing
construction power;

·                  Providing
construction fire protection;

·                  Providing
electrical and mechanical underground systems;

·                  Preparing Site
for heavy lift cranes;

·                  Relocation of
alternate power source and fiber optics lines for the existing V. C. Summer
Plant;

·                  Removal and
disposal of abandoned utilities off Site;

·                  Relocation of
lines for the construction transformer;

·                  Removal and
disposal of abandoned fencing and gates off Site:

·                  Removal and
disposal of concrete blocks off Site:

·                  Construction
security infrastructure

·                  Excavation and
backfill

·                  Selection and
preparation of spoils areas

·                  Batch plant

·                  Common fill and
backfill storage locations; and

·                  Water treatment
to support construction

 

A.1.6       COL
Supporl and Other Requested Services

 

Services in support of the COL (non-NuStart), or other
services that may be required in Phase I, will be on an as-needed basis, as specifically
requested by Owner, and will be provided [**].

 

A.1.7       Phase I
Deliverables

 

Listed below are the deliverables for Phase I:

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page 13 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

A.    Project
Management

 

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

 

B.             Procurement
Activities

 

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

 

C.    Site Specific Activities

 

·                  [**];

·                  [**];

·                  [**];

·                  [**];

·                  [**];

·                  [**];

·                  [**];

·                  [**];

·                  [**];

·                  [**];

·                  [**];

·                  [**];

·                  [**];

·                  [**];

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page 14 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

·                  [**];

·                  [**];

·                  [**];

·                  [**];

·                  [**];

·                  [**];

·                  [**];

·                  [**];

·                  [**]; and

·                  [**].

 

A.2          Phase
II

 

Contractor will supply [**] AP1000 Nuclear Power Plant Units
to be located at the Site, except for those items listed in Table 1 as Owner’s
Responsibility and Nuclear Fuel, which will be provided by Owner.

 

The Standard Plant description is provided in the AP1000
Design Control Document.  The Standard
Plant will include Units as described in Revision 16 of the Design Control
Document , including Technical Report 134, “AP1000 DCD Impacts to
Support COLA Standardization,” APP-GW-GLR-134.  Revision 4 and the Design Change Packages approved for implementation
as of the Effective Date.  Interfaces
with existing Site facilities and systems are shown in Figure 1, Site
Plan.  Contractor’s scope includes
design, engineering, procurement, installation, and testing necessary to
provide the AP1000 Nuclear Power Plant structures and systems described.  Contractor’s scope of services with division
of responsibilities between Owner and Contractor is provided in Table 1.

 

Documentation to be provided by the Contractor to the Owner
as developed for the Facility is listed in Table 2.

 

In accordance with the requirements of Section 3.6(f) of
the Agreement, during the implementation of Phase II, Mandatory Spare Parts
will be identified in Table 3.

 

[**]

 

1.0 Plant Description

 

Contractor will provide each AP1000 Nuclear Power Plant
utilizing the NRC Certified AP1000 Design. 
A comprehensive description is provided in the Design Control

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page 15 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Document, which was the basis of the submittal to the NRC
under the provisions of 10 CFR Part 52.

 

The AP1000 Nuclear Power Plants meet applicable safety
requirements and goals defined for advanced light water pressurized water
reactors with passive safety features and provides for a greatly simplified
plant with respect to design, licensing, construction, operation, inspection
and maintenance.

 

[**]

 

2.0 Plant Arrangement

 

The plant arrangement will be comprised of five principal
building structures; the nuclear island, the turbine building, the annex
building, the diesel generator building, and the radwaste building.

 

Details of the AP1000 Site Plan and Building Arrangement are
illustrated in the attached Design Control Document (DCD) Figure 1.2-2.

 

The functional allocation of system components contained in
the buildings is identified in the attached DCD Figure 1.2-3.

 

SITE SPECIFIC SYSTEMS

 

The
systems that are specific to the V C Summer site are the Circulating Water
System, Storm Drain System, Potable Water System, Raw Water System, Sanitary
Drainage System, Waste Water System and the Yard Fire System. In addition,
portions of the Electrical Grounding and Lightning Protection System and the
Electrical Site Power Distribution System are specific to the V C Summer site.

 

The reference
plant main cooling tower-circulating water pump complex consists of a natural
draft cooling tower, a pump basin, and circulating water pumps. The cooling
tower for the Owner’s Site will be an induction draft.

 

Circulating
Water System (CWS) — CWS supplies cooling water to the main condenser,
turbine building closed cooling water system (TCS) heat exchangers, condenser
vacuum pump seal water (CMS) heat exchangers and rejects the waste heat to the
atmosphere through cooling towers. [**]

 

Raw
Water System (RWS) — RWS provides raw water from site sources to CWS.
The RWS system contains [**] and the intake pumps.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
16 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Storm
Drain System (DRS) - The Storm Drain System (DRS) keeps the AP1000
power block facilities and the site specific facilities free from localized
flooding during a storm. The DRS system [**].

 

Potable
Water System (PWS) — PWS furnishes water for domestic use and human
consumption. The PWS system [**].

 

Sanitary
Drainage System (SDS) — SDS collects sanitary waste from Site rest
rooms and building drains and transports it to treatment and discharge.  During construction this system will tie into
a temporary sanitary treatment facility until the permanent facility is
constructed.  Construction city will have
a separate sanitary treatment facility. 
The SDS system [**].

 

Waste
Water System (WWS) - WWS collects non-radioactive plant process waste
effluents (excluding sanitary and storm drains), provides appropriate means of
treating waste effluents, oil separation and discharges treated waste effluent.
The WWS system [**].

 

Yard
Fire System (YFS) - The Yard Fire System (YFS) detects and suppresses
fires outside the Standard Plant during plant construction and operation.  The YFS consists of water distribution
systems, automatic and manual suppression systems, fire detection and alarm
system, and portable fire extinguishers. The YFS system [**].

 

Electrical
Site Power Distribution System (ESPDS) — ESPDS provides the
electrical power for all construction (temporary power) and retail (permanent
and temporary) loads for the Units.

 

Grounding
and Lightning Protection System (EGS) — The grounding and
lightning protection system provides personnel safety and investment protection
by maintaining safe voltages across the station during high voltage transients,
providing a low impedance ground fault current return path, minimizing noise
interference and minimizing the effects of lighting surges.

 

Transmission Switchyard - A switchyard
will be used to transmit electrical power output from the AP1000 units to the
South Carolina Electric and Gas (SCE&G) and Santee Cooper 230kV
transmission systems. The switchyard will also be used as a power source for
plant auxiliaries when the units are in the startup or shutdown modes, or when
the units are not generating. The switchyard is constructed in a 10 bay,
breaker-and-half arrangement.  The switchyard connection to the AP1000
units is made through additional 230kV circuit breakers provided at the high
side connections of the main step up transformers and reserve auxiliary
transformers.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
17 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

PERMANENT BUILDINGS AND STRUCTURES

 

These
buildings and structures are a part of the permanent Facility but are outside
the footprint of the AP1000 Standard Plant.

 

Permanent
Plant Buildings and Structures include:

 

·                  Maintenance Support Service Building

·                  Personnel Access Point Building

·                  Permanent Warehouse

·                  Raw Water Intake Structure

·                  230 kV Switchyard Control Building

·                  Circulating Water System Switchgear and MCC
Buildings

·                  Circulating Water System Pump Structures

·                  Cooling Tower Foundations

·                  Blowdown Sump

·                  RWS Switchgear and MCC Building

·                  Waste Water Discharge Structure

·                  Lampson Crane Pads

 

2.4 Security Infrastructure

 

The security infrastructure associated with the AP1000 Plant
includes the security system (SES) for the design and hardware inside the
Standard Plant and the access portals, equipment and barriers to control access
to the Protected Area.  The Protected
Area access and barriers will be designed and constructed to include:

 

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

 

A detailed description of the Site security infrastructure
will be provided in Phase 1.

 

3.0          Test Program

 

The overall objective of the test program is to demonstrate
that the plant has been constructed as designed, that the systems perform
consistent with the plant design, and

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page 18 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

that activities culminating in operation at full licensed
power including initial fuel load, initial criticality, and power ascension are
performed in a controlled and safe manner.

 

The plant test program consists of a series of tests
categorized as Construction and Installation Tests, Preoperational Tests,
Startup Tests and Performance Test.  The
test program is described in the Agreement.

 

Plant operating, emergency, and surveillance procedures are
incorporated into the initial test program procedures. These procedures are
verified through use, to the extent practicable, during the Preoperational Test
program and revised if necessary, prior to fuel loading.

 

Equipment used in the performance of Preoperational Tests is
operated in accordance with appropriate operating procedures, thereby giving
Owner’s operating staff an opportunity to gain experience in using these
procedures and demonstrating their adequacy prior to plant initial criticality.

 

Where applicable, Preoperational Tests may proceed on an
individual system that has completed its Construction and Installation Test,
prior to completion of all Construction and Installation Tests.

 

3.1          Startup
Administrative Manual

 

[**] for a manual (“Startup Administrative Manual”)  and
administrative procedures that provide detailed requirements and govern the
execution of activities associated with the conduct of the test program,
including the organization, structure and functional relationships of the Joint
Test Working Group and the startup organization.  Preparation of the Startup Administrative
Manual is [**].  The Startup
Administrative Manual will address the following:

 

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page 19 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

·                  [**]

·                  [**]

·                  [**]

 

[**] for review and evaluation of individual test results as
well as final review of overall test results and for review of selected
Milestones [**] within the test phases. Test exceptions or results which do not
meet acceptance criteria are identified to the affected and responsible design organizations,
and corrective actions and retests, as required, are performed.

 

3.2          Organization

 

The specific staff, staff responsibilities,
authorities, and personnel qualifications for performance of the AP1000 initial
test program are the responsibility of the Owner. This test organization is
responsible for the [**] Unit initial testing and related activities that occur
between the completion of plant/system/component construction and commencement
of Unit commercial operation. Transfer and retention of experience and
knowledge gained during initial testing for the subsequent commercial operation
of the Unit is an objective of the test program.

 

Contractor’s personnel providing testing services, Technical
Support and/or field support shall work with the Owner’s operating organization
in the test organization (hereinafter referred to as the “Joint Test Working
Group”).  [**]  The Joint Test Working Group will review and
evaluate Construction and Installation Test, Preoperational Test and Startup
Test results and test Turnover packages and recommend acceptance of the
Turnover to the Owner.

 

The Joint Test Working Group shall be responsible for
ensuring that preoperational and startup activities are performed correctly and
completely in accordance with the COL requirements.

 

The Joint Test Working Group shall provide to Owner a
preoperational and startup schedule. 
This detailed schedule shall incorporate a logical sequence of testing
formulated on modular construction and testing of structures, areas, equipment,
components, and systems.  The schedule
shall also be prepared to account for use of temporary construction power as
needed to support operations and testing if permanent

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page 20 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

power is not available, as well as the use of a temporary
demineralizer to facilitate flushing of piping systems if the permanent plant
demineralizer is not available.  The test
schedule shall support Contractor’s overall construction schedule for the Unit.

 

A Preoperational Test group (“Preoperational Test Group”)
will be established by the Joint Test Working Group and be manned by the
Contractor and Owner personnel as mutually agreed by Owner and Contractor.  The Preoperational Test Group will consist of
engineering test leads and test personnel. 
The Preoperational Test Group will perform the following functions and
scope of work, as necessary to support the test program:

 

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

 

A Startup Test group (“Startup Test Group”) will be
established by the Joint Test Working Group and be initially manned by
Contractor and Owner personnel as mutually agreed by Owner and Contractor.  The Startup Test Group will consist of
engineering test leads and test personnel. 
The Startup Test Group will perform the following functions and scope of
work, as necessary to support the test program:

 

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

 

A test support group (“Test Support Group”) will be
established by the Joint Test Working Group and be manned by Contractor and
Owner personnel as mutually agreed by Owner and Contractor.  The Test Support Group will consist of
manpower and labor as needed to support all testing activities.

 

The Joint Test Working Group, while coordinating the test
program will interface with Owner’s operations personnel in the initial
starting and operation of the various systems.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page 21 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Responsibilities

 

3.3.1       Joint Test Working
Group Activities

 

In general, the main activities of the Joint Test Working
Group during Preoperational Tests and Startup Tests shall include, but not be
limited to, the following:

 

1.                                       [**]

 

2.                                       [**]

 

3.                                       [**]

 

4.                                       [**]

 

5.                                       [**]

 

6.                                       [**]

 

7.                                       [**]

 

8.                                       [**]

 

9.                                       [**]

 

10.                                 [**]

 

11.                                 [**]

 

12.                                 [**]

 

13.                                 [**]

 

14.                                 [**]

 

15.                                 [**]

 

16.                                 [**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page 22 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

3.3.2       Responsibilities of
Owner

 

Owner’s responsibilities include,
but are not limited to:

 

1.                                       [**]

 

2.                                       [**]

 

3.                                       [**]

 

4.                                       [**]

 

5.                                       [**]

 

6.                                       [**]

 

7.                                       [**]

 

3.3.3                    General

 

If deviations or unresolved issues are encountered during
testing, Contractor and Owner shall immediately proceed to identify the
problems and their causes.  Contractor
shall then develop and take necessary corrective actions to resolve deviations
and unresolved issues covered under Contractor’s Scope of Work.  Owner shall then develop and take necessary
corrective actions to resolve deviations and unresolved issues not covered
under Contractor’s Scope of Work or resulting from an operating or maintenance
issue.  Contractor or Owner shall perform
these actions in a timely manner to maintain the startup schedule.  Contractor’s liability in resolving and
correcting the deviations and/or unresolved issues shall be subject to the
provisions of the Agreement.

 

[**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page 23 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

3.4          Lists of Documents
and Procedures for Preoperational and Startup Operations

 

Contractor shall submit to Owner the description of
documents used for tests and a detailed list of test documents as required in
the Startup Administrative Manual procedures. 
The Joint Test Working Group shall prepare test programs, procedures,
and documentation suitably adapted to Site specific conditions.  After the test, the test report shall be
prepared by the Joint Test Working Group and submitted to Owner.

 

3.5                               Qualification Requirements of Personnel for Preoperational and Startup
Testing

 

Personnel
engaged in Preoperational Test and Startup Test activities shall be suitably
qualified and experienced for the level of responsibility and importance to
safety of their work.

 

3.6                               Contractors
Craft and Maintenance Support during Preoperational
and Startup Testing activities

 

Contractor will supply craft and maintenance support
personnel to assist the Joint Test Working Group and Owner’s maintenance
organization on a Time and Materials Basis. 
The Contractor craft and maintenance support personnel necessary will be
defined in the detailed plans for Construction and Installation Tests, Preoperational
Tests, and Startup Tests.

 

4.0 Scope of Supply

 

Table 1 details the responsibilities between the Owner (O) and
Contractor (X) for providing the Site infrastructure, temporary
facilities, buildings/ structures, plant systems, major equipment, modules and
components which comprises each AP1000 Nuclear Power Plant. Each building is
detailed as to its physical composition. The functional Equipment, components
and commodities that comprise each system are highlighted. The table also
depicts those program responsibilities for design, temporary facilities,
program management, construction, testing, startup and commissioning of each
facility.  The items listed in Table 1
define the base scope of supply for the Agreement.  Changes due to Supplier design maturity or
Supplier initiated Design Change Packages (DCPs) may be made without impact to
the Owner.  Changes driven by the Owner
are subject to Change Order.

 

In Table 1, the following definitions of column headings and
letter symbols apply:

 

“O” means the Owner and its representatives.

 

“X” means the Contractor.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page 24 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

“Design Criteria” are the functional requirements and data
required for the basic engineering of Site works, buildings, structures,
modules systems or equipment.

 

“Detail Design” means the engineering analyses, calculations
and detail design drawings and specifications in accordance with the “design
criteria” for the supply, erection and construction of Site works, buildings,
structures, modules, systems or equipment.

 

“Eq/Comp/Com Supply” means the procurement and supply of
necessary material, components and equipment specified for Site works,
buildings, structures, modules and systems.

 

“Install /Construct” means the erection, installation or
construction of all mechanical and electrical equipment and systems and the
completion of all temporary works, civil works including finishes and
architectural treatments.

 

“Establish Requirements” specifies the party responsible for
identifying and establishing the necessary activities that must be completed
and provided.

 

“Provide For” establishes the party responsible for
executing the scope including cost accountability and performance
responsibility.

 

Where two organizations are shown for a specific task, the
organization (O/X or X/O) first listed has lead responsibility and the second
has responsibility to support.

 

[**]

 

[**]

 

In accordance with the Project Execution Plan, the method of
providing [**] will be mutually agreed upon during Phase 1.  Pricing will include a line item for the
expected disposition of the [**] during or in closeout of the project.  Contractor and Owner will mutually agree upon
the disposition of the [**], once their purpose has been met.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page 25 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT A – TABLE 1

SCOPE OF WORK / SUPPLY

AND DIVISION OF RESPONSIBILITY

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page 26 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT A-TABLE 1 SCOPE of WORK/SUPPLY AND DIVISION OF
RESPONSIBILITIES

 

	
  PROJECT SERVICES

  	
  ESTABLISH

  REQUIREMENTS

  	
  PROVIDE FOR

  
	
  Project
  Management

  	
  [**]

  	
  [**]

  
	
  Engineering &
  Design (Non NuStart)

  	
  [**]

  	
  [**]

  
	
  Construction
  Management

  	
  [**]

  	
  [**]

  
	
  Site
  Engineering

  	
  [**]

  	
  [**]

  
	
  Nuclear
  Safety/Licensing (post NuStart)

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  COLA
  and Licensing Support (T&M basis as required)

  	
  [**]

  	
  [**]

  

 

	
  ENGINEERED PROGRAMS

  	
  Design

  Criteria

  	
  Program

  Development

  	
  Program

  Implementation

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
27 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  ENGINEERED PROGRAMS

  	
  Design

  Criteria

  	
  Program

  Development

  	
  Program

  Implementation

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

	
  SERVICES

  	
  Design

  Criteria

  	
  Program

  Development

  	
  Program

  Implementation

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Site
  Material Control

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Operator
  and Staff Training

  	
  [**]

  	
  [**]

  	
  [**]

  

 

	
  OTHER SCOPE

  	
  ESTABLISH

  REQUIREMENTS

  	
  PROVIDE

  FOR

  
	
  Spare
  Parts (to be defined in accordance with Agreement)

  	
  [**]

  	
  [**]

  
	
  Shop
  and Maintenance Equipment (Table 4)

  	
  [**]

  	
  [**]

  
	
  COLA
  and Licensing Support (T&M Basis as required)

  	
  [**]

  	
  [**]

  
	
  Consumables
  First Fill

  	
  [**]

  	
  [**]

  

 

	
  INSURANCE

  	
  ESTABLISH

  REQUIREMENTS

  	
  PROVIDE

  FOR

  
	
  Per
  Agreement Articles 15 and 16

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page 28 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  TESTING, STARTUP & COMMISSIONING

  	
  ESTABLISH

  REQUIREMENTS

  	
  PROVIDE

  FOR

  
	
  AP1000
  Startup Program Development and Technical Direction of Initial Test Program

  	
  [**]

  	
  [**]

  
	
  Simulator
  hardware

  	
  [**]

  	
  [**]

  
	
  O &
  M Training

  	
  [**]

  	
  [**]

  
	
  Test
  Equipment

  	
  [**]

  	
  [**]

  
	
  Construction
  (Functional) Testing

  	
  [**]

  	
  [**]

  
	
  Preoperational
  Testing

  	
  [**]

  	
  [**]

  
	
  Startup
  (Functional) Tests

  	
  [**]

  	
  [**]

  
	
  Maintenance
  following System Turnover

  	
  [**]

  	
  [**]

  
	
  Pre-
  Service Inspection (ASME Section XI)

  	
  [**]

  	
  [**]

  
	
  Core
  Loading

  	
  [**]

  	
  [**]

  
	
  Initial
  Criticality

  	
  [**]

  	
  [**]

  
	
  Performance
  Tests

  	
  [**]

  	
  [**]

  
	
  In-Service
  Inspection

  	
  [**]

  	
  [**]

  
	
  Test
  Reports

  	
  [**]

  	
  [**]

  
	
  Testing
  and Operating Procedures

  	
  [**]

  	
  [**]

  
	
  Special
  Tools, Laboratory, Calibration & Test Equipment

  	
  [**]

  	
  [**]

  

 

	
  GENERAL & ADMINISTRATIVE

  	
  ESTABLISH

  REQUIREMENTS

  	
  PROVIDE

  FOR

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page 29 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  GENERAL & ADMINISTRATIVE

  	
  ESTABLISH

  REQUIREMENTS

  	
  PROVIDE

  FOR

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  

 

	
  CONSTRUCTION SERVICES

  	
  ESTABLISH

  REQUIREMENTS

  	
  PROVIDE FOR

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page 30 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  CONSTRUCTION SERVICES

  	
   

  	
  ESTABLISH

  REQUIREMENTS

  	
  PROVIDE FOR

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
31 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  DESCRIPTION

  	
   

  	
  SINGLE- POINT RESPONSIBILITY

  	
   

  
	
   

  	
   

  	
  Design

  Criteria

  	
  Detail

  Design

  	
  EQ/Comp

  Com. Supply

  	
  Install

  Construct

  
	
  SITE INFRASTRUCTURE

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  SITE DEVELOPMENT & PREPARATION

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
   

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
32 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  DESCRIPTION

  	
   

  	
  SINGLE- POINT RESPONSIBILITY

  	
   

  
	
   

  	
   

  	
  Design

  Criteria

  	
  Detail

  Design

  	
  EQ/Comp

  Com. Supply

  	
  Install

  Construct

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  ROADS

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  RAILROAD

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  RAW, POTABLE & FIRE SUPPRESSION WATER

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  PERMANENT PLANT FACILITIES

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
33 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  DESCRIPTION

  	
   

  	
  SINGLE- POINT RESPONSIBILITY

  	
   

  
	
   

  	
   

  	
  Design

  Criteria

  	
  Detail

  Design

  	
  EQ/Comp

  Com. Supply

  	
  Install

  Construct

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
34 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  DESCRIPTION

  	
   

  	
  SINGLE- POINT RESPONSIBILITY

  	
   

  
	
   

  	
   

  	
  Design

  Criteria

  	
  Detail

  Design

  	
  EQ/Comp

  Com. Supply

  	
  Install

  Construct

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

	
  WORK

  BREAKDOWN

  	
   

  	
  DESCRIPTION

  	
   

  	
  SINGLE-
  POINT RESPONSIBILITY

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
  Design

  Criteria

  	
  Detail

  Design

  	
  EQ/Comp

  Com.

  Supply

  	
  Install

  Construct

  	
  Scope

  	
  DOR

  
	
   

  	
   

  	
  BUILDINGS &
  STRUCTURES

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  1100

  	
   

  	
  Shield
  Building, complete structure & finishes

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
  Containment,
  complete structure & finishes

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  1200

  	
   

  	
  Auxiliary
  Building, complete structure & finishes

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  2000

  	
   

  	
  Turbine
  Building, complete structure & finishes

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  4000

  	
   

  	
  Annex
  Building, complete structure & finishes

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  5000

  	
   

  	
  Radwaste
  Building, complete structure & finishes

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  6000

  	
   

  	
  Diesel
  Generator Building, complete structure & finishes

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
35 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  WORK

  BREAKDOWN

  	
  DESCRIPTION

  	
   

  	
  SINGLE- POINT RESPONSIBILITY

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
  Design

  Criteria

  	
  Detail

  Design

  	
  EQ/Comp

  Com.

  Supply

  	
  Install

  Construct

  	
  Scope

  	
  DOR

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  SYSTEMS,
  EQUIPMENT, COMPONENTS & COMMODITIES

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  ASS

  	
  Auxiliary
  Steam Supply System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  BDS

  	
  Steam
  Generator Blowdown

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  CCS

  	
  Component
  Cooling Water System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  CAS

  	
  Compressed
  Air System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  CDS

  	
  Condensate
  System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  CES

  	
  Condenser
  Tube Cleaning System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  CFS

  	
  Turbine
  Island Chemical Feed System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  CMS

  	
  Condenser
  Air Removal System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  CNS

  	
  Containment
  System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  CPS

  	
  Condensate
  Polishing System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  CVS

  	
  Chemical &
  Volume Control System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  CWS

  	
  Circulating
  Water System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  DAS

  	
  Diverse
  Actuation System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
36 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  WORK

  BREAKDOWN

  	
  DESCRIPTION

  	
  SINGLE-
  POINT RESPONSIBILITY

  
	
   

  	
   

  	
  Design

  Criteria

  	
  Detail

  Design

  	
  EQ/Comp

  Com.

  Supply

  	
  Install

  Construct

  	
  Scope

  	
  DOR

  
	
  DDS

  	
  Data
  Display & Processing System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  DOS

  	
  Standby
  Diesel Fuel System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  DRS

  	
  Storm
  Drain System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  DTS

  	
  Dematerialized
  Water Treatment System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  DWS

  	
  Dematerialized
  Water Transfer & Storage System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  ECS

  	
  Main
  AC Power plant electrical system

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  EDS

  	
  Non
  Class 1E DC & UPS System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  EFS

  	
  Communications
  System, plant wide

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  EGS

  	
  Grounding &
  Lightning Protection System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  EHS

  	
  Special
  Process Heat Tracing System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  ELS

  	
  Plant
  Lighting System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  EQS

  	
  Cathodic
  Protection System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  FHS

  	
  Fuel
  Handling & Refueling System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  FPS

  	
  Fire
  Protection System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  FWS

  	
  Main &
  Startup Feedwater System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page
37 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  WORK

  BREAKDOWN

  	
  DESCRIPTION

  	
  SINGLE-
  POINT RESPONSIBILITY

  
	
   

  	
   

  	
  Design

  Criteria

  	
  Detail

  Design

  	
  EQ/Comp

  Com.

  Supply

  	
  Install

  Construct

  	
  Scope

  	
  DOR

  
	
  GSS

  	
  Gland
  Seal System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  HCS

  	
  Generator
  Hydrogen & CO2 Systems

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  HDS

  	
  Heater
  Drain System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  HSS

  	
  Hydrogen
  Seal Oil System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  IDS

  	
  Class 1E
  DC and UPS System (Division A to D)

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  IIS

  	
  Incore
  Instrumentation System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  LOS

  	
  Main
  Turbine & Generator Lube Oil System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  MES

  	
  Meteorological &
  Environmental Monitoring System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  MHS

  	
  Mechanical
  Handling System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  MSS

  	
  Main
  Steam System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  MTS

  	
  Main
  Turbine System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  OCS

  	
  Operation &
  Control Centers

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  PCS

  	
  Passive
  Containment Cooling System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  PGS

  	
  Plant
  Gas System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  PLS

  	
  Plant
  Control System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 38 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  WORK

  BREAKDOWN

  	
  DESCRIPTION

  	
  SINGLE-
  POINT RESPONSIBILITY

  
	
   

  	
   

  	
  Design

  Criteria

  	
  Detail

  Design

  	
  EQ/Comp

  Com.

  Supply

  	
  Install

  Construct

  	
  Scope

  	
  DOR

  
	
  PMS

  	
  Protection &
  Safety Monitoring System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  PSS

  	
  Primary
  Sampling System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  PWS

  	
  Potable
  Water System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  PXS

  	
  Passive
  Core Cooling System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  RCS

  	
  Reactor
  Coolant System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  RDS

  	
  Gravity &
  Roof Drain Collection System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  RMS

  	
  Radiation
  Monitoring System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  RNS

  	
  Normal
  Residual Heat Removal System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  RWS

  	
  Raw
  Water System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  RXS

  	
  Reactor
  System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  SDS

  	
  Sanitary
  Drainage System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  SES

  	
  Plant
  Security System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  SFS

  	
  Spent
  Fuel Pit Cooling System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  SGS

  	
  Steam
  Generator System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  SJS

  	
  Seismic
  Monitoring System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 39 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  WORK

  BREAKDOWN

  	
  DESCRIPTION

  	
   

  	
  SINGLE-
  POINT RESPONSIBILITY

  
	
   

  	
   

  	
   

  	
  Design

  Criteria

  	
  Detail

  Design

  	
  EQ/Comp

  Com.

  Supply

  	
  Install

  Construct

  	
  Scope

  	
  DOR

  
	
  SMS

  	
  Special
  Monitoring System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  SSS

  	
  Secondary
  Sampling System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  STS

  	
  Simulator
  Training System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  SWS

  	
  Service
  Water System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  TCS

  	
  Turbine
  Bldg. Closed Cooling Water System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  TDS

  	
  Turbine
  Island Vents, Drains & Relief System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  TOS

  	
  Main
  Turbine Control & Diagnostics

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  TVS

  	
  Closed
  Circuit TV System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  VAS

  	
  Radiologically
  Controlled Area Ventilation system

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  VBS

  	
  Nuclear
  Island. Non-radioactive Ventilation System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  VCS

  	
  Containment
  Recirculation Cooling System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  VES

  	
  Main
  Control Rm. Emergency Habitability System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  VFS

  	
  Containment
  Air Filtration System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  VHS

  	
  Health
  Physics & Hot Machine Shop HVAC System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  VLS

  	
  Containment
  Hydrogen Control System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page
40 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  WORK

  BREAKDOWN

  	
  DESCRIPTION

  	
   

  	
  SINGLE-
  POINT RESPONSIBILITY

  
	
   

  	
   

  	
   

  	
  Design

  Criteria

  	
  Detail

  Design

  	
  EQ/Comp

  Com.

  Supply

  	
  Install

  Construct

  	
  Scope

  	
  DOR

  
	
  VRS

  	
  Radwaste
  Building HVAC System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  VTS

  	
  Turbine
  Building Ventilation System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  VUS

  	
  Containment
  Leak Rate Test Systems

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  VWS

  	
  Central
  Chilled Water System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  VXS

  	
  Annex/Aux
  Bldg Non-radioactive Ventil. System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  VYS

  	
  Hot
  Water Heating System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  VZS

  	
  Diesel Gen. Bldg. Ventilation System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  WGS

  	
  Gaseous
  Radwaste System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  WLS

  	
  Liquid
  Radwaste System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  WRS

  	
  Radioactive
  Waste Drain System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  WSS

  	
  Solid
  Radwaste System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  WWS

  	
  Waste
  Water System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  ZAS

  	
  Main
  Generation System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  ZBS

  	
  Transmission
  Switchyard & Offsite Power System - Plant Feed Only

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  ZOS

  	
  Onsite
  Standby Power System

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page
41 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  WORK

  BREAKDOWN

  	
  DESCRIPTION

  	
  SINGLE-
  POINT RESPONSIBILITY

  
	
   

  	
   

  	
  Design

  Criteria

  	
  Detail

  Design

  	
  EQ/Comp

  Com.

  Supply

  	
  Install

  Construct

  	
  Scope

  	
  DOR

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  ZVS

  	
  Excitation &
  Voltage Regulation System

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  

 

Notes:

·                  [**]

·                  [**]

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

Page 42 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Notes for Preceding Section

 

	
  Note

  	
  System

  	
  Details

  
	
  Scope
  of Work Notes:

  
	
  1

  	
  See Table

  	
  [**]

  
	
  2

  	
  CFS

  	
  [**]

  
	
  3

  	
  CWS

  	
  [**]

  
	
  4

  	
  DOS

  	
  [**]

  
	
  5

  	
  DRS

  	
  [**]

  
	
  6

  	
  EFS

  	
  [**]

  
	
  7

  	
  EGS

  	
  [**]

  
	
  8

  	
  ELS

  	
  [**]

  
	
  9

  	
  EQS

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 43 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Notes for Preceding Section

 

	
  Note

  	
  System

  	
  Details

  
	
  Scope
  of Work Notes:

  
	
  10

  	
  FHS

  	
  [**]

  	
   

  
	
   

  	
   

  	
  [**] 

  	
  [**]

  
	
   

  	
   

  	
  [**] 

  	
  [**]

  
	
  11

  	
  MES

  	
  [**]

  	
   

  
	
  12

  	
  PGS

  	
  [**]

  	
   

  
	
  13

  	
  PLS

  	
  [**]

  	
   

  
	
  14

  	
  PWS

  	
  [**]

  	
   

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 44 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Notes for Preceding Section

 

	
  Note

  	
  System

  	
  Details

  
	
  Scope
  of Work Notes:

  
	
  15

  	
  RMS

  	
  [**]

  
	
  16

  	
  RWS

  	
  [**]

  
	
  17

  	
  SDS

  	
  [**]

  
	
  18

  	
  SES

  	
  [**]

  
	
  19

  	
  SJS

  	
  [**]

  
	
  20

  	
  STS

  	
  [**]

  
	
  21

  	
  TVS

  	
  [**]

  
	
  22

  	
  VUS

  	
  [**]

  
	
  23

  	
  WLS

  	
  [**]

  
	
  24

  	
  WWS

  	
  [**]

  
	
  25

  	
   

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 45 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Notes for Preceding Section

 

	
  Note

  	
  System

  	
  Details

  
	
  Scope
  of Work Notes:

  
	
  26

  	
  ZBS

  	
  [**]

  
	
  27

  	
  ZOS

  	
  [**]

  
	
  Division
  of Responsibility Notes

  
	
  a

  	
  RXS

  	
  [**]

  
	
  b

  	
  STS

  	
  [**]

  
	
  c

  	
   

  	
  [**]

  
	
  d

  	
   

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
46 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

080509

 

EXHIBIT A Table 2

AP1000 Documentation Deliverables

 

AP1000 Facility Information classified as Proprietary Class 2
Releasable (i.e., deliverable under this Agreement) and Non-Proprietary Class 3
documents specifically related to the design, construction, operation and
maintenance of the Facility provided under this Agreement shall be provided
from the Contractor’s Information Management System (IMS) in electronic format
via access through a controlled website or similar electronic information
portal.  The final list of the
documentation types to be provided for Owner’s access will be developed by
Contractor and approved by the Owner during Phase I, and expected to include
but not limited to the types of deliverable documents as provided in Table 2-1.

 

Instructions for access to these documents shall be provided
by Contractor for use by Owner’s personnel, including listing of index fields
and query options. This information may be electronically posted on the IMS.
The controlled documents will be provided with revision level control, and be
uniquely designated.

 

[**]

 

[**]

 

Proprietary Class 2 Releasable information is sensitive
business and technical information that Owner may not disclose without
Contractor’s prior written authorization except as otherwise provided in Article
19 of the Agreement.  Proprietary Class 2
Releasable documents will be marked “Proprietary Class 2”.  [**]

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 47 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

[**]

 

Non-Proprietary Class 3 information is
non-sensitive information that may be distributed both internally and
externally to Contractor. This is information which, if published, would not
result in the loss of an existing or potential competitive advantage and may be
released on an unrestricted basis. Class 3 is primarily used to describe
technical reports, association review papers, and/or marketing and advertising
literature.

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 48 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Table 2-1

Types of Deliverable Documents

 

GENERAL AND ADMINISTRATIVE

 

·                  [**]

·                  [**]

·                  [**]

 

PROJECT MANAGEMENT

 

·                  [**]

·                  [**]

·                  Project
Schedule (includes Engineering, Procurement, QA and Construction)

·                  Project
Change Notices [**]

·                  Official
Project Correspondence

·                  Monthly
Progress Reports [**]

 

QUALITY ASSURANCE

 

·                  Contractor Project Quality Plan

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

 

ENGINEERING

 

Systems:

 

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 49 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

·      [**]

·      [**]

·      [**]

·      [**]

 

Equipment

 

·      [**]

·      [**]

·      [**]

·      [**]

·      [**]

·      [**]

·      [**]

·      [**]

·      [**]

·      [**]

 

Relevant AP1000 Building Drawings and Reports, including

 

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

 

PROCUREMENT

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 50 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

·                  [**]

·                  [**]

·                  [**]

·                  [**]

 

CONSTRUCTION

 

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

 

TESTING & STARTUP

 

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

·                  [**]

 

Note 1:                      [**]

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 51 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT A — Table 3

AP1000 Mandatory Spare Parts

 

Mandatory Spare Parts list will be inserted here as
developed during the completion of the Facility.

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 52 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT A – Table 4

AP1000 Special Tools

 

This list of Special Tools may be updated through Design
Finalization and Initial Testing.

 

	
  WBS

  	
  Description

  	
  Data Sheet

  
	
  3.403.

  	
  [**]

  	
   

  
	
  U1X4033_MZ01

  	
  [**]

  	
  MZ41-Z0D-001

  
	
  U1X4033_MZ02

  	
  [**]

  	
  MZ42-Z0D-001

  
	
  U1X4033_MZ03

  	
  [**]

  	
  MZ43-Z0D-001

  
	
  U1X4033_MZ04

  	
  [**]

  	
  MZ44-Z0D-001

  
	
  U1X4033_MZ05

  	
  [**]

  	
  MZ45-Z0D-001

  
	
  U1X4033_MZ06

  	
  [**]

  	
  MZ46-Z0D-001

  
	
  U1X4033_MZ07

  	
  [**]

  	
  MZ47-Z0D-001

  
	
  U1X4033_MZ08

  	
  [**]

  	
  MZ48-Z0D-001

  
	
  U1X4033_MZ09

  	
  [**]

  	
  MZ49-Z0D-001

  
	
  U1X4033_MZ10

  	
  [**]

  	
  MZ50-Z0D-001

  
	
  U2X4033_MZ01

  	
  [**]

  	
  MZ41-Z0D-001

  
	
  U2X4033_MZ02

  	
  [**]

  	
  MZ42-Z0D-001

  
	
  U2X4033_MZ03

  	
  [**]

  	
  MZ43-Z0D-001

  
	
  U2X4033_MZ04

  	
  [**]

  	
  MZ44-Z0D-001

  
	
  U2X4033_MZ05

  	
  [**]

  	
  MZ45-Z0D-001

  
	
  U2X4033_MZ06

  	
  [**]

  	
  MZ46-Z0D-001

  
	
  U2X4033_MZ07

  	
  [**]

  	
  MZ47-Z0D-001

  
	
  U2X4033_MZ08

  	
  [**]

  	
  MZ48-Z0D-001

  
	
  U2X4033_MZ09

  	
  [**]

  	
  MZ49-Z0D-001

  
	
  U2X4033_MZ10

  	
  [**]

  	
  MZ50-Z0D-001

  
	
  3.CCS.MZ3G

  	
  [**]

  	
   

  
	
  U1ACCS__MZ01A

  	
  [**]

  	
  MZ3G-Z0D-001

  
	
  U1ACCS__MZ01B

  	
  [**]

  	
  MZ3G-Z0D-001

  
	
  U1ACCS__MZ01C

  	
  [**]

  	
  MZ3G-Z0D-001

  
	
  U1ACCS__MZ01D

  	
  [**]

  	
  MZ3G-Z0D-001

  
	
  U2ACCS__MZ01A

  	
  [**]

  	
  MZ3G-Z0D-001

  
	
  U2ACCS__MZ01B

  	
  [**]

  	
  MZ3G-Z0D-001

  
	
  U2ACCS__MZ01C

  	
  [**]

  	
  MZ3G-Z0D-001

  
	
  U2ACCS__MZ01D

  	
  [**]

  	
  MZ3G-Z0D-001

  
	
  3.CVS.MZ00

  	
  [**]

  	
   

  
	
  U1NCVS__MZ01

  	
  [**]

  	
  MZ3J-Z0D-001

  
	
  U1NCVS__MZ02

  	
  [**]

  	
  MZ3K-Z0D-001

  
	
  U1NCVS__MZ03

  	
  [**]

  	
  MZ3L-Z0D-001

  
	
  U1NCVS__MZ04

  	
  [**]

  	
  MZ3M-Z0D-001

  
	
  U2NCVS__MZ01

  	
  [**]

  	
  MZ3J-Z0D-001

  
	
  U2NCVS__MZ02

  	
  [**]

  	
  MZ3K-Z0D-001

  
	
  U2NCVS__MZ03

  	
  [**]

  	
  MZ3L-Z0D-001

  
	
  U2NCVS__MZ04

  	
  [**]

  	
  MZ3M-Z0D-001

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page
53 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  WBS

  	
  Description

  	
  Data Sheet

  
	
  3.FHS.FH50

  	
  [**]

  	
   

  
	
  U1MFHS__FH50

  	
  [**]

  	
  FH50-Z0D-001

  
	
  U2MFHS__FH50

  	
  [**]

  	
  FH50-Z0D-001

  
	
  3.FHS.FH51

  	
  [**]

  	
   

  
	
  U1MFHS__FH51

  	
  [**]

  	
  FH51-Z0D-001

  
	
  U2MFHS__FH51

  	
  [**]

  	
  FH51-Z0D-001

  
	
  3.FHS.FH52

  	
  [**]

  	
   

  
	
  U1MFHS__FH52

  	
  [**]

  	
  FH52-Z0D-001

  
	
  U2MFHS__FH52

  	
  [**]

  	
  FH52-Z0D-001

  
	
  3.FHS.FH53

  	
  [**]

  	
   

  
	
  U1MFHS__FH53

  	
  [**]

  	
  FH53-Z0D-001

  
	
  U2MFHS__FH53

  	
  [**]

  	
  FH53-Z0D-001

  
	
  3.FHS.FH54

  	
  [**]

  	
   

  
	
  U1MFHS__FH54

  	
  [**]

  	
  FH54-Z0D-001

  
	
  U2MFHS__FH54

  	
  [**]

  	
  FH54-Z0D-001

  
	
  3.FHS.FH55

  	
  [**]

  	
   

  
	
  U1MFHS__FH55

  	
  [**]

  	
  FH55-Z0D-001

  
	
  U2MFHS__FH55

  	
  [**]

  	
  FH55-Z0D-001

  
	
  3.FHS.FH56

  	
  [**]

  	
   

  
	
  U1MFHS__FH56

  	
  [**]

  	
  FH56-Z0D-001

  
	
  U2MFHS__FH56

  	
  [**]

  	
  FH56-Z0D-001

  
	
  3.FHS.FH57

  	
  [**]

  	
   

  
	
  U1MFHS__FH57

  	
  [**]

  	
  FH57-Z0D-001

  
	
  U2MFHS__FH57

  	
  [**]

  	
  FH57-Z0D-001

  
	
  3.FHS.FH58

  	
  [**]

  	
   

  
	
  U1MFHS__FH58

  	
  [**]

  	
  FH58-Z0D-001

  
	
  U2MFHS__FH58

  	
  [**]

  	
  FH58-Z0D-001

  
	
  3.FHS.FH59

  	
  [**]

  	
   

  
	
  U1MFHS__FH59

  	
  [**]

  	
  FH59-Z0D-001

  
	
  U2MFHS__FH59

  	
  [**]

  	
  FH59-Z0D-001

  
	
  3.FHS.FH60

  	
  [**]

  	
   

  
	
  U1MFHS__FH60

  	
  [**]

  	
  FH60-Z0D-001

  
	
  U1MFHS__FH61

  	
  [**]

  	
  FH60-Z0D-001

  
	
  U2MFHS__FH60

  	
  [**]

  	
  FH60-Z0D-001

  
	
  U2MFHS__FH61

  	
  [**]

  	
  FH60-Z0D-001

  
	
  3.FHS.FS09

  	
  [**]

  	
   

  
	
  U1MFHS__FS08

  	
  [**]

  	
  FS09-Z0D-001

  
	
  U2MFHS__FS08

  	
  [**]

  	
  FS09-Z0D-001

  
	
  3.FHS.MZ01

  	
  [**]

  	
   

  
	
  U1MFHS__MZ01A

  	
  [**]

  	
  MZ01-Z0D-001

  
	
  U1MFHS__MZ01B

  	
  [**]

  	
  MZ01-Z0D-001

  
	
  U1MFHS__MZ01C

  	
  [**]

  	
  MZ01-Z0D-001

  
	
  U1MFHS__MZ01D

  	
  [**]

  	
  MZ01-Z0D-001

  
	
  U1MFHS__MZ101A

  	
  [**]

  	
  MZ1A-Z0D-001

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page
54 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  WBS

  	
  Description

  	
  Data Sheet

  
	
  U1MFHS__MZ101B

  	
  [**]

  	
  MZ1A-Z0D-001

  
	
  U1MFHS__MZ101C

  	
  [**]

  	
  MZ1A-Z0D-001

  
	
  U1MFHS__MZ101D

  	
  [**]

  	
  MZ1A-Z0D-001

  
	
  U2MFHS__MZ01A

  	
  [**]

  	
  MZ01-Z0D-001

  
	
  U2MFHS__MZ01B

  	
  [**]

  	
  MZ01-Z0D-001

  
	
  U2MFHS__MZ01C

  	
  [**]

  	
  MZ01-Z0D-001

  
	
  U2MFHS__MZ01D

  	
  [**]

  	
  MZ01-Z0D-001

  
	
  U2MFHS__MZ101A

  	
  [**]

  	
  MZ1A-Z0D-001

  
	
  U2MFHS__MZ101B

  	
  [**]

  	
  MZ1A-Z0D-001

  
	
  U2MFHS__MZ101C

  	
  [**]

  	
  MZ1A-Z0D-001

  
	
  U2MFHS__MZ101D

  	
  [**]

  	
  MZ1A-Z0D-001

  
	
  3.FHS.MZ07

  	
  [**]

  	
   

  
	
  U1MFHS__MZ07

  	
  [**]

  	
  MZ07-Z0D-001

  
	
  U2MFHS__MZ07

  	
  [**]

  	
  MZ07-Z0D-001

  
	
  3.FHS.MZ13

  	
  [**]

  	
   

  
	
  U1MFHS__MZ13

  	
  [**]

  	
  MZ13-Z0D-001

  
	
  U2MFHS__MZ13

  	
  [**]

  	
  MZ13-Z0D-001

  
	
  3.FHS.MZ14

  	
  [**]

  	
   

  
	
  U1MFHS__MZ14

  	
  [**]

  	
  MZ14-Z0D-001

  
	
  U2MFHS__MZ14

  	
  [**]

  	
  MZ14-Z0D-001

  
	
  3.FHS.MZ15

  	
  [**]

  	
   

  
	
  U1MFHS__MZ15

  	
  [**]

  	
  MZ15-Z0D-001

  
	
  U2MFHS__MZ15

  	
  [**]

  	
  MZ15-Z0D-001

  
	
  3.FHS.MZ16

  	
  [**]

  	
   

  
	
  U1MFHS__MZ16

  	
  [**]

  	
  MZ16-Z0D-001

  
	
  U2MFHS__MZ16

  	
  [**]

  	
  MZ16-Z0D-001

  
	
  3.FHS.MZ17

  	
  [**]

  	
   

  
	
  U1MFHS__MZ17

  	
  [**]

  	
  MZ17-Z0D-001

  
	
  U2MFHS__MZ17

  	
  [**]

  	
  MZ17-Z0D-001

  
	
  3.FHS.MZRV.Z1B

  	
  [**]

  	
   

  
	
  U1MFHS__MZ102A

  	
  [**]

  	
  MZ1B-Z0D-001

  
	
  U1MFHS__MZ102B

  	
  [**]

  	
  MZ1B-Z0D-001

  
	
  U1MFHS__MZ102C

  	
  [**]

  	
  MZ1B-Z0D-001

  
	
  U1MFHS__MZ102D

  	
  [**]

  	
  MZ1B-Z0D-001

  
	
  U2MFHS__MZ102A

  	
  [**]

  	
  MZ1B-Z0D-001

  
	
  U2MFHS__MZ102B

  	
  [**]

  	
  MZ1B-Z0D-001

  
	
  U2MFHS__MZ102C

  	
  [**]

  	
  MZ1B-Z0D-001

  
	
  U2MFHS__MZ102D

  	
  [**]

  	
  MZ1B-Z0D-001

  
	
  3.FHS.MZRV.Z1C

  	
  [**]

  	
   

  
	
  U1MFHS__MZ103A

  	
  [**]

  	
  MZ1C-Z0D-001

  
	
  U1MFHS__MZ103B

  	
  [**]

  	
  MZ1C-Z0D-001

  
	
  U1MFHS__MZ103C

  	
  [**]

  	
  MZ1C-Z0D-001

  
	
  U1MFHS__MZ103D

  	
  [**]

  	
  MZ1C-Z0D-001

  
	
  U2MFHS__MZ103A

  	
  [**]

  	
  MZ1C-Z0D-001

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page
55 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  WBS

  	
  Description

  	
  Data Sheet

  
	
  U2MFHS__MZ103B

  	
  [**]

  	
  MZ1C-Z0D-001

  
	
  U2MFHS__MZ103C

  	
  [**]

  	
  MZ1C-Z0D-001

  
	
  U2MFHS__MZ103D

  	
  [**]

  	
  MZ1C-Z0D-001

  
	
  3.FHS.MZRV.Z1D

  	
  [**]

  	
   

  
	
  U1MFHS__MZ104A

  	
  [**]

  	
  MZ1D-Z0D-001

  
	
  U1MFHS__MZ104B

  	
  [**]

  	
  MZ1D-Z0D-001

  
	
  U1MFHS__MZ104C

  	
  [**]

  	
  MZ1D-Z0D-001

  
	
  U1MFHS__MZ104D

  	
  [**]

  	
  MZ1D-Z0D-001

  
	
  U2MFHS__MZ104A

  	
  [**]

  	
  MZ1D-Z0D-001

  
	
  U2MFHS__MZ104B

  	
  [**]

  	
  MZ1D-Z0D-001

  
	
  U2MFHS__MZ104C

  	
  [**]

  	
  MZ1D-Z0D-001

  
	
  U2MFHS__MZ104D

  	
  [**]

  	
  MZ1D-Z0D-001

  
	
  3.FHS.MZRV.Z1E

  	
  [**]

  	
   

  
	
  U1MFHS__MZ105A

  	
  [**]

  	
  MZ1E-Z0D-001

  
	
  U1MFHS__MZ105B

  	
  [**]

  	
  MZ1E-Z0D-001

  
	
  U1MFHS__MZ105C

  	
  [**]

  	
  MZ1E-Z0D-001

  
	
  U1MFHS__MZ105D

  	
  [**]

  	
  MZ1E-Z0D-001

  
	
  U2MFHS__MZ105A

  	
  [**]

  	
  MZ1E-Z0D-001

  
	
  U2MFHS__MZ105B

  	
  [**]

  	
  MZ1E-Z0D-001

  
	
  U2MFHS__MZ105C

  	
  [**]

  	
  MZ1E-Z0D-001

  
	
  U2MFHS__MZ105D

  	
  [**]

  	
  MZ1E-Z0D-001

  
	
  3.FHS.MZRV.Z1F

  	
  [**]

  	
   

  
	
  U1MFHS__MZ106

  	
  [**]

  	
  MZ1F-Z0D-001

  
	
  U2MFHS__MZ106

  	
  [**]

  	
  MZ1F-Z0D-001

  
	
  3.FHS.MZRV.Z1H

  	
  [**]

  	
   

  
	
  U1MFHS__MZ200

  	
  [**]

  	
  MZ1H-Z0D-001

  
	
  U2MFHS__MZ200

  	
  [**]

  	
  MZ1H-Z0D-001

  
	
  3.FHS.MZRV.Z1J

  	
  [**]

  	
   

  
	
  U1MFHS__MZ111A

  	
  [**]

  	
  MZ1J-Z0D-001

  
	
  U1MFHS__MZ111B

  	
  [**]

  	
  MZ1J-Z0D-001

  
	
  U1MFHS__MZ111C

  	
  [**]

  	
  MZ1J-Z0D-001

  
	
  U1MFHS__MZ111D

  	
  [**]

  	
  MZ1J-Z0D-001

  
	
  U2MFHS__MZ111A

  	
  [**]

  	
  MZ1J-Z0D-001

  
	
  U2MFHS__MZ111B

  	
  [**]

  	
  MZ1J-Z0D-001

  
	
  U2MFHS__MZ111C

  	
  [**]

  	
  MZ1J-Z0D-001

  
	
  U2MFHS__MZ111D

  	
  [**]

  	
  MZ1J-Z0D-001

  
	
  3.FHS.MZRV.Z1K

  	
  [**]

  	
   

  
	
  U1MFHS__MZ121

  	
  [**]

  	
  MZ1K-Z0D-001

  
	
  U2MFHS__MZ121

  	
  [**]

  	
  MZ1K-Z0D-001

  
	
  3.FHS.MZRV.Z1L

  	
  [**]

  	
   

  
	
  U1MFHS__MZ131

  	
  [**]

  	
  MZ1L-Z0D-001

  
	
  U2MFHS__MZ131

  	
  [**]

  	
  MZ1L-Z0D-001

  
	
  3.FWS.MZ2A

  	
  [**]

  	
   

  
	
  U1PFWS__MZ01

  	
  [**]

  	
  MZ2A-Z0D-001

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page
56 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  WBS

  	
  Description

  	
  Data Sheet

  
	
  U2PFWS__MZ01

  	
  [**]

  	
  MZ2A-Z0D-001

  
	
  3.IDS.DB01.HWE

  	
  [**]

  	
   

  
	
  U1EIDSA_DY001

  	
  [**]

  	
  DB01-Z0D-001T

  
	
  U2EIDSA_DY001

  	
  [**]

  	
  DB01-Z0D-001T

  
	
  3.MHS

  	
  [**]

  	
   

  
	
  U1MMHS__MH18

  	
  [**]

  	
  MH18-Z0D-001

  
	
  U1MMHS__MH19A

  	
  [**]

  	
  MH19-Z0D-001

  
	
  U1MMHS__MH19B

  	
  [**]

  	
  MH19-Z0D-001

  
	
  U1MMHS__MHEXTRA-1

  	
  [**]

  	
  MH18-Z0D-001

  
	
  U1MMHS__MHEXTRA-3

  	
  [**]

  	
  MH18-Z0D-001

  
	
  U2MMHS__MH18

  	
  [**]

  	
  MH18-Z0D-001

  
	
  U2MMHS__MH19A

  	
  [**]

  	
  MH19-Z0D-001

  
	
  U2MMHS__MH19B

  	
  [**]

  	
  MH19-Z0D-001

  
	
  U2MMHS__MHEXTRA-1

  	
  [**]

  	
  MH18-Z0D-001

  
	
  U2MMHS__MHEXTRA-3

  	
  [**]

  	
  MH18-Z0D-001

  
	
  3.RCS.MH17.HWE

  	
  [**]

  	
   

  
	
  UCRRCS__MH01

  	
  [**]

  	
  MH17-Z0D-001

  
	
  3.RCS.MZ19

  	
  [**]

  	
   

  
	
  U1RRCS__MZ01

  	
  [**]

  	
  MZ19-Z0D-001

  
	
  U2RRCS__MZ01

  	
  [**]

  	
  MZ19-Z0D-001

  
	
  3.RCS.MZ3A

  	
  [**]

  	
   

  
	
  U1RRCS__MZ30

  	
  [**]

  	
  MZ3A-Z0D-001

  
	
  U2RRCS__MZ30

  	
  [**]

  	
  MZ3A-Z0D-001

  
	
  3.RCS.MZ3B

  	
  [**]

  	
   

  
	
  U1RRCS__MZ31A

  	
  [**]

  	
  MZ3B-Z0D-001

  
	
  U1RRCS__MZ31B

  	
  [**]

  	
  MZ3B-Z0D-001

  
	
  U2RRCS__MZ31A

  	
  [**]

  	
  MZ3B-Z0D-001

  
	
  U2RRCS__MZ31B

  	
  [**]

  	
  MZ3B-Z0D-001

  
	
  3.RCS.MZ3C

  	
  [**]

  	
   

  
	
  U1RRCS__MZ32A

  	
  [**]

  	
  MZ3C-Z0D-001

  
	
  U1RRCS__MZ32B

  	
  [**]

  	
  MZ3C-Z0D-001

  
	
  U1RRCS__MZ32C

  	
  [**]

  	
  MZ3C-Z0D-001

  
	
  U1RRCS__MZ32D

  	
  [**]

  	
  MZ3C-Z0D-001

  
	
  U2RRCS__MZ32A

  	
  [**]

  	
  MZ3C-Z0D-001

  
	
  U2RRCS__MZ32B

  	
  [**]

  	
  MZ3C-Z0D-001

  
	
  U2RRCS__MZ32C

  	
  [**]

  	
  MZ3C-Z0D-001

  
	
  U2RRCS__MZ32D

  	
  [**]

  	
  MZ3C-Z0D-001

  
	
  3.RCS.MZ3D

  	
  [**]

  	
   

  
	
  U1RRCS__MZ33A

  	
  [**]

  	
  MZ3D-Z0D-001

  
	
  U1RRCS__MZ33B

  	
  [**]

  	
  MZ3D-Z0D-001

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page
57 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  WBS

  	
  Description

  	
  Data Sheet

  
	
  U1RRCS__MZ33C

  	
  [**]

  	
  MZ3D-Z0D-001

  
	
  U1RRCS__MZ33D

  	
  [**]

  	
  MZ3D-Z0D-001

  
	
  U2RRCS__MZ33A

  	
  [**]

  	
  MZ3D-Z0D-001

  
	
  U2RRCS__MZ33B

  	
  [**]

  	
  MZ3D-Z0D-001

  
	
  U2RRCS__MZ33C

  	
  [**]

  	
  MZ3D-Z0D-001

  
	
  U2RRCS__MZ33D

  	
  [**]

  	
  MZ3D-Z0D-001

  
	
  3.RCS.MZ3E

  	
  [**]

  	
   

  
	
  U1RRCS__MZ34

  	
  [**]

  	
  MZ3E-Z0D-001

  
	
  U1RRCS__MZ35

  	
  [**]

  	
  MZ3F-Z0D-001

  
	
  U2RRCS__MZ34

  	
  [**]

  	
  MZ3E-Z0D-001

  
	
  U2RRCS__MZ35

  	
  [**]

  	
  MZ3F-Z0D-001

  
	
  3.RNS.MZ3N

  	
  [**]

  	
   

  
	
  U1NRNS__MZ01

  	
  [**]

  	
  MZ3N-Z0D-001

  
	
  U2NRNS__MZ01

  	
  [**]

  	
  MZ3N-Z0D-001

  
	
  3.RNS.MZ3Q

  	
  [**]

  	
   

  
	
  U1NRNS__MZ11

  	
  [**]

  	
  MZ3Q-Z0D-001

  
	
  U2NRNS__MZ11

  	
  [**]

  	
  MZ3Q-Z0D-001

  
	
  3.RXS.MY90.HWE

  	
  [**]

  	
   

  
	
  U1RRXS__MYY01

  	
  [**]

  	
  MY90-Z0D-001

  
	
  U2RRXS__MYY01

  	
  [**]

  	
  MY90-Z0D-001

  
	
  3.SFS.MZ3H

  	
  [**]

  	
   

  
	
  U1NSFS__MZ01A

  	
  [**]

  	
  MZ3H-Z0D-001

  
	
  U1NSFS__MZ01B

  	
  [**]

  	
  MZ3H-Z0D-001

  
	
  U1NSFS__MZ01C

  	
  [**]

  	
  MZ3H-Z0D-001

  
	
  U1NSFS__MZ01D

  	
  [**]

  	
  MZ3H-Z0D-001

  
	
  U2NSFS__MZ01A

  	
  [**]

  	
  MZ3H-Z0D-001

  
	
  U2NSFS__MZ01B

  	
  [**]

  	
  MZ3H-Z0D-001

  
	
  U2NSFS__MZ01C

  	
  [**]

  	
  MZ3H-Z0D-001

  
	
  U2NSFS__MZ01D

  	
  [**]

  	
  MZ3H-Z0D-001

  
	
  3.SWS.MZ3P

  	
  [**]

  	
   

  
	
  U1ASWS__MZ01

  	
  [**]

  	
  MZ3P-Z0D-001

  
	
  U2ASWS__MZ01

  	
  [**]

  	
  MZ3P-Z0D-001

  
	
  3.WSS.MH60

  	
  [**]

  	
   

  
	
  U1MMHS__MH60

  	
  [**]

  	
  MH60-Z0D-001

  
	
  U1WWSS__MR01

  	
  [**]

  	
  MH60-Z0D-001

  
	
  U1WWSS__MR02

  	
  [**]

  	
  MH60-Z0D-001

  
	
  U1WWSS__MSCART

  	
  [**]

  	
  MH60-Z0D-002

  
	
  U1WWSS__MZ02

  	
  [**]

  	
  MH60-Z0D-004

  
	
  U1WWSS__MZ04

  	
  [**]

  	
  MH60-Z0D-006

  
	
  U1WWSS__MZ05

  	
  [**]

  	
  MH60-Z0D-007

  
	
  U2MMHS__MH60

  	
  [**]

  	
  MH60-Z0D-001

  
	
  U2WWSS__MR01

  	
  [**]

  	
  MH60-Z0D-001

  
	
  U2WWSS__MR02

  	
  [**]

  	
  MH60-Z0D-001

  
	
  U2WWSS__MSCART

  	
  [**]

  	
  MH60-Z0D-001

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page
58 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  WBS

  	
  Description

  	
  Data Sheet

  
	
  U2WWSS__MZ01

  	
  [**]

  	
  MH60-Z0D-001

  
	
  U2WWSS__MZ02

  	
  [**]

  	
  MH60-Z0D-001

  
	
  U2WWSS__MZ03

  	
  [**]

  	
  MH60-Z0D-001

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 59 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT
A  Figures

 

Figure 1. Site Plan - Interface with Existing Site
Facilities and Systems

 

 

“[**]” in this Exhibit 10.01 indicates material that has
been omitted pursuant to a request for confidential treatment and filed
separately with the Securities and Exchange Commission.

 

Page 60 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT
A  Figures

 

[**]

 

“[**]” in this Exhibit 10.01 indicates material that has
been omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 61 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT
A  Figures

 

DCD
Figure 1.2-3, Functional Allocation of System Components Contained in Buildings

 

[**]

 

“[**]” in this Exhibit 10.01 indicates material that has
been omitted pursuant to a request for confidential treatment and filed
separately with the Securities and Exchange Commission.

 

Page 62 of 62

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT
B

Contractor’s
Organization

 

“[**]” in this Exhibit 10.01 indicates material that has
been omitted pursuant to a request for confidential treatment and filed
separately with the Securities and Exchange Commission.

 

Page 1 of 2

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

 

“[**]” in this Exhibit 10.01 indicates material that has
been omitted pursuant to a request for confidential treatment and filed
separately with the Securities and Exchange Commission.

 

Page 2 of 2

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT C

Permits

 

X = CONTRACTOR
RESPONSIBILITY

O = OWNER RESPONSIBILITY

(Where both are listed,
the Party first listed has the lead responsibility and the second one has the
responsibility to support)

 

	
  Listing of Required Permits and Licenses

  
	
  PERMITS,
  PLANS, & DETERMINATIONS

  NEEDED

  	
  PERMIT

  TYPE

  	
  DESIGN
  DATA

  NEEDED (Y/N)

  	
  DEVELOP

  PERMIT

  	
  OWNER
  /

  HOLDER

  	
  IMPLEMENT

  PERMIT

  
	
  Well Permit
  (Groundwater Wells)

  (SC R61-71) 

  	
  State DHEC

  	
  Y

  	
  X

  	
  X

  	
  X

  
	
  Negative declaration on
  cultural resources from the State Historic Preservation Officer (SHPO)

  (36 CFR Part 800)

  	
  State

  	
  N

  	
  N/A

  	
  N/A

  	
  N/A

  
	
  Negative declaration on
  endangered species from the U.S. Fish and Wildlife Services (USFWS)

  (50 CFR Parts 13, 17, 222, 226, 227, 402, 424, 450-453)

  	
  Federal

  	
  N/A

  	
  N/A

  	
  N/A

  	
  N/A

  
	
  Negative declaration on
  endangered species from South Carolina Department of Natural Resources
  (SCDNR)

  (50 CFR Parts 13, 17, 222, 226, 227, 402, 424, 450-453)

  	
  State

  	
  N/A

  	
  N/A

  	
  N/A

  	
  N/A

  
	
  Wetlands 404 Permit
  from U.S. Army Corps of Engineers (COE)

  (33 CFR 328)

  	
  Federal

  	
  Y

  	
  O/X

  	
  O

  	
  X

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

1 of 8

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT C

Permits

 

	
  Listing of Required Permits and Licenses

  
	
  PERMITS,
  PLANS, & DETERMINATIONS

  NEEDED

  	
  PERMIT

  TYPE

  	
  DESIGN
  DATA

  NEEDED (Y/N)

  	
  DEVELOP

  PERMIT

  	
  OWNER /

  HOLDER

  	
  IMPLEMENT

  PERMIT

  
	
  Floodplain
  Assessment

  (E.O. 11988)

  	
  Federal

  	
  N/A

  	
  N/A

  	
  N/A

  	
  N/A

  
	
  Federal
  Aviation Administration § 77.15 Permit

  (14 CFR 77)

  	
  Federal

  	
  Y

  	
  X

  	
  X

  	
  X

  
	
  PERMITS, PLANS, & DETERMINATIONS NEEDED
  FOR ANY CONSTRUCTION

  
	
  Air Quality Protection Permitting

  
	
  DOE
  Spent Fuel Agreement/Contract (NWPA 1982)

  	
  Federal

  	
  N

  	
  O

  	
  O

  	
  O

  
	
  Bureau
  of Air Quality Construction Permit (May include contractor small
  sources)

  (SC R. 61-62)

  	
  State DHEC

  	
  Y

  	
  O/X

  	
  O

  	
  X

  
	
  Concrete
  Batch Plant BAQ Permit (Form IIF) (May be part of BAQ Construction Permit)

  (SC R. 61-62)

  	
  State DHEC

  	
  Y

  	
  O/X

  	
  O

  	
  X

  
	
  Surface Water Protection Permitting

  
	
  Dam
  Repair/Alterations Permit

  (SC R. 72-1 through R. 72-9)

  	
  State DHEC

  	
  N/A

  	
  N/A

  	
  N/A

  	
  N/A

  
	
  Water
  Use Permit (Water withdrawal from Broad River)

  	
  Federal

  	
  N/A

  	
  N/A

  	
  N/A

  	
  N/A

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

2 of 8

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT C

Permits

 

	
  Listing of Required Permits and Licenses

  
	
  PERMITS,
  PLANS, & DETERMINATIONS

  NEEDED

  	
  PERMIT

  TYPE

  	
  DESIGN
  DATA

  NEEDED (Y/N)

  	
  DEVELOP

  PERMIT

  	
  OWNER /

  HOLDER

  	
  IMPLEMENT

  PERMIT

  
	
  Sec
  401 Water Quality Certification (SCDHEC)

  (SC R61-101)

  	
  State

  	
  Y

  	
  O/X

  	
  O

  	
  X

  
	
  Public
  Water Supply System (Potable Water)

  (SC R. 61-58.)

  	
  State DHEC

  	
  Y

  	
  O/X

  	
  O

  	
  X

  
	
  Sec
  404 Dredge & Fill Permit (Corps of Engineers) Dredging of Ponds and
  River (33 CFR 323)  Construction in
  Wetlands (33 CFR 330)  Wetland and/or
  stream fill Construction of Intake/Discharge Structures (33 CFR
  322/Section 10 Rivers and Harbors Act)and Impact to Navigable Waters (33
  USC 403)

  	
  Federal/  State

  	
  Y

  	
  O/X

  	
  O

  	
  X

  
	
  County
  Septic Tank Permit

  	
  County

  	
  N/A

  	
  N/A

  	
  N/A

  	
  N/A

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

3 of 8

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT C

Permits

 

	
  Listing of Required Permits and Licenses

  
	
  PERMITS,
  PLANS, & DETERMINATIONS

  NEEDED

  	
  PERMIT

  TYPE

  	
  DESIGN
  DATA

  NEEDED (Y/N)

  	
  DEVELOP

  PERMIT

  	
  OWNER /

  HOLDER

  	
  IMPLEMENT

  PERMIT

  
	
  NPDES
  Permit to Construct Sanitary Wastewater Wastewater Treatment Intake Structure
  (33 CFR 322) Discharge structure (SC R. 61-9)

  	
  State DHEC

  	
  Y

  	
  O/X

  	
  O

  	
  X

  
	
  NPDES
  Permit - Concrete Batch Plant (SC R. 61-9)

  	
  State DHEC

  	
  Y

  	
  O/X

  	
  O

  	
  X

  
	
  NPDES
  Stormwater Permit Construction Storm Water Pollution Prevention Plan (SWPPP) Erosion
  Control Plan Grading Permit Notice of Intent (NOI) (SC R. 61-9)

  	
  State DHEC

  	
  Y

  	
  O/X

  	
  O

  	
  X

  
	
  CZMA
  Approval / Waiver

  	
  State/Federal

  	
  Y

  	
  O

  	
  O

  	
  O

  
	
  Facility
  Response Plan for Oil Spills (40 CFR 112, SC R. 61-9 BMP)

  	
  State

  	
  N/A

  	
  N/A

  	
  N/A

  	
  N/A

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

4 of 8

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT C

Permits

 

	
  Listing of Required Permits and Licenses

  
	
  PERMITS,
  PLANS, & DETERMINATIONS

  NEEDED

  	
  PERMIT

  TYPE

  	
  DESIGN
  DATA

  NEEDED (Y/N)

  	
  DEVELOP

  PERMIT

  	
  OWNER /

  HOLDER

  	
  IMPLEMENT

  PERMIT

  
	
  Groundwater/Drinking Water Protection Permitting

  
	
  Diesel Fuel Storage Tank (UST) Installation
  Permit (Potentially not required for above ground tanks)

  (SC R. 61-92)

  	
  State DHEC

  	
  N/A

  	
  N/A

  	
  N/A

  	
  N/A

  
	
  Waste
  Management Permitting

  
	
  Construction &
  Demolition Landfill

  (SC R. 61-71, R. 61-107.258, R. 61-107.11, and R. 61-107.13)

  	
  State DHEC

  	
  Y

  	
  O/X

  	
  O

  	
  X

  
	
  Pollution
  Prevention and Waste Minimization Plan (RCRA)

  (SC R. 61-79, and SC R. 61-104)

  	
  State DHEC

  	
  N/A

  	
  N/A

  	
  N/A

  	
  N/A

  
	
  Process
  Waste Disposal/RCRA ID Number

  (SC R. 61-79, and SC R. 61-104)

  	
  State DHEC

  	
  Y

  	
  O/X

  	
  O

  	
  X

  
	
  Used
  Oil Disposal

  (SC R. 61-79, and SC R. 61-104)

  	
  State

  	
  N/A

  	
  N/A

  	
  N/A

  	
  N/A

  
	
  Miscellaneous Permits

  
	
  NRC
  COL

  	
  NRC

  	
  N/A

  	
  N/A

  	
  N/A

  	
  N/A

  
	
  FERC
  License Revision (Project 1894)

  	
  FERC License

  	
  Y

  	
  O/X

  	
  O

  	
  O

  
	
  ASME
  Owners Certification (NCA-3230)

  	
  ASME

  	
  N/A

  	
  O

  	
  O

  	
  O

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

5 of 8

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT C

Permits

 

	
  Listing of Required Permits and Licenses

  
	
  PERMITS,
  PLANS, & DETERMINATIONS

  NEEDED

  	
  PERMIT

  TYPE

  	
  DESIGN
  DATA

  NEEDED (Y/N)

  	
  DEVELOP

  PERMIT

  	
  OWNER /

  HOLDER

  	
  IMPLEMENT

  PERMIT

  
	
  Parr/FFPS
  and Railroad Easements

  	
  SCE&G

  	
  Y

  	
  O/X

  	
  O

  	
  O

  
	
  SC
  Business License

  	
  State

  	
  N/A

  	
  N/A

  	
  N/A

  	
  N/A

  
	
  Release
  from “Land Application” status for areas in and around L50.

  	
  State DHEC

  	
  N/A

  	
  N/A

  	
  N/A

  	
  N/A

  
	
  Engineering
  Report [International Building Codes, Sec 1704)

  (Fairfield Co Building Safety)

  	
  County

  	
  Y

  	
  X

  	
  X

  	
  X

  
	
  Building
  Permit [Offices & warehouses only]

  (Fairfield Co Building Safety)

  	
  County

  	
  Y

  	
  X

  	
  X

  	
  X

  
	
  DOT
  Highway Encroachment/Modifications

  	
  State DOT

  	
  N/A

  	
  N/A

  	
  N/A

  	
  N/A

  
	
  Blasting
  Permit

  	
  State

  	
  N

  	
  X

  	
  X

  	
  X

  
	
  Certificate
  of Public Convenience and Necessity (SC Public Service Commission)

  	
  State

  	
  Y

  	
  O/X

  	
  O

  	
  O

  
	
  PERMITS, PLANS, & DETERMINATIONS NEEDED
  FOR OPERATION

  
	
  Air Quality Protection Permitting

  
	
  Title
  V Air Operating Permit or Conditional Major Source Permit

  (SC R. 61-62)

  	
  State DHEC

  	
  Y

  	
  O/X

  	
  O

  	
  O

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

6 of 8

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT C

Permits

 

	
  Listing of Required Permits and Licenses

  
	
  PERMITS,
  PLANS, & DETERMINATIONS

  NEEDED

  	
  PERMIT

  TYPE

  	
  DESIGN
  DATA

  NEEDED (Y/N)

  	
  DEVELOP

  PERMIT

  	
  OWNER /

  HOLDER

  	
  IMPLEMENT

  PERMIT

  
	
  Surface Water Protection Permitting

  
	
  NPDES
  Permit Sanitary Wastewater Discharge Wastewater Treatment Discharge Cooling Tower
  Blowdown Discharge

  (SC R. 61-9)

  	
  State DHEC

  	
  Y

  	
  O/X

  	
  O

  	
  O

  
	
  Operations
  SPCC Plan

  (40 CFR 112, SC R. 61-9)

  	
  State

  	
  Y

  	
  N/A

  	
  N/A

  	
  N/A

  
	
  NPDES
  Operations Stormwater Permit Operations Storm Water Pollution Prevention Plan
  (SWPPP) (SC R. 61-9)

  	
  State  DHEC

  	
  Y

  	
  O/X

  	
  O

  	
  O

  
	
  Groundwater/Drinking Water Protection Permitting

  
	
  Diesel
  Fuel Storage Tank (UST) Operating Permit (Potentially not required for above
  ground tanks) (SC
  R. 61-92)

  	
  State DHEC

  	
  N/A

  	
  N/A

  	
  N/A

  	
  N/A

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

7 of 8

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT C

Permits

 

	
  Listing of Required Permits and Licenses

  
	
  PERMITS,
  PLANS, & DETERMINATIONS

  NEEDED

  	
  PERMIT

  TYPE

  	
  DESIGN
  DATA

  NEEDED (Y/N)

  	
  DEVELOP

  PERMIT

  	
  OWNER /

  HOLDER

  	
  IMPLEMENT

  PERMIT

  
	
  Waste Management Permitting

  
	
  Process
  Waste Disposal/RCRA ID Number

  (SC R. 61-79, and SC R. 61-104)

  	
  State

  	
  Y

  	
  O/X

  	
  O

  	
  O

  
	
  Pollution
  Prevention and Waste Minimization Plan

  (SC R. 61-79, and SC R. 61-104)

  	
  State

  	
  Y

  	
  O/X

  	
  O

  	
  O

  
	
  Radioactive
  Materials/Transport License

  (SC R 61-63 and R 61-83)

  	
  State DHEC

  	
  N

  	
  O

  	
  O

  	
  O

  
	
  SNM
  License

  10 CFR 30, 40 and 70

  	
  Federal NRC

  	
  N

  	
  O

  	
  O

  	
  O

  
	
  Certificate
  to Transport Hazardous Materials

  (40 CFR and SC R 61-79)

  	
  Federal/ DOT

  	
  N

  	
  O

  	
  O

  	
  O

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

8 of 8

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT D

AP1000 —Project
Execution Plan Processes

 

Capitalized
terms used herein and not otherwise defined herein have the meanings assigned
to such terms in the Agreement to which this Exhibit D is appended.

 

The Project Execution
Plan will incorporate the following processes. 
The Parties may mutually agree to modify the title or description of
such processes or add additional processes to the Project Execution Plan.

 

	
  Process Title

  	
   

  	
  Process
  Description

  
	
   

  	
   

  	
   

  
	
  Project
  Management Plan

  	
   

  	
  Describes the project
  organizational structure, work scope and division of responsibilities, top
  level project schedule and list of key deliverables. Outlines the
  responsibility assignments, top level principles, strategies, systems and
  processes employed in the project. This process will address the Limited
  Notice(s) to Proceed issued by Owner to authorize the Phase 1 Work. This
  process will also address Project Schedule adjustments, including those
  related to first concrete pouring and COL approval.

  
	
   

  	
   

  	
   

  
	
  Risk
  Management

  	
   

  	
  Defines process to
  identify, assess, categorize manage and track risk items. It includes process
  to report status of risk mitigation and track to completion.

  
	
   

  	
   

  	
   

  
	
  Schedule

  	
   

  	
  Defines the process of
  creating and controlling the Project Schedule with an agreed integrated work
  breakdown structure for the identification of activity (IDs) with appropriate
  links between design finalization, procurement and construction.

  
	
   

  	
   

  	
   

  
	
  Supply
  Chain/Procurement Plan

  	
   

  	
  Describes processes,
  procedures, roles and responsibilities for the demand plan, supply plan, risk
  management and procurement/logistics processes for the purchase of goods and
  services. Provides a coordinated strategy to ensure on-time delivery of cost
  effective, quality products and services.

  
	
   

  	
   

  	
   

  
	
  Construction
  Execution Plan

  	
   

  	
  Establish the
  construction philosophy and planned approach for the AP1000 Standard Plant,
  such that execution of the construction portion of the Work will be completed
  in accordance with the requirements of the Agreement and Subcontracts.  This plan defines the scope of
  the construction portion of the Work, Contractor’s project management team’s
  organization, and how the construction portion of the Work will be managed.

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
1 of 4

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Process Title

  	
   

  	
  Process
  Description

  
	
   

  	
   

  	
   

  
	
  Module
  Plan

  	
   

  	
  Document the process
  and infrastructure required for completion of module planning, design,
  procurement, fabrication and assembly, testing, delivery, storage, Site
  assembly, outfitting and installation to support construction of the AP1000
  Nuclear Power Plant (the “AP1000”). Establishes process for vendor selection
  and lists selected fabricators for each module. Lists the
  structural/mechanical modules and piping assemblies and identifies
  Contractor’s or Subcontractors’  organizations
  responsible for design/supply of each module.

  
	
   

  	
   

  	
   

  
	
  Quality
  Assurance Plan

  	
   

  	
  Description of
  requirements of Quality Assurance Program  and how
  the Westinghouse Quality Management System and Shaw Stone & Webster
  Quality Assurance Program are implemented and identifies supplemental
  procedures that will be required.

  
	
   

  	
   

  	
   

  
	
  Process
  Improvement/Lessons Learned

  	
   

  	
  Process to identify and
  evaluate lessons learned from AP1000 and other projects and maintain them in
  a centralized system. Describes how to submit, evaluate and distribute
  lessons learned and recommend corrective actions.

  
	
   

  	
   

  	
   

  
	
  Project
  Engineering Plan

  	
   

  	
  An upper level program
  document that provides the description and guidance for executing the
  responsibilities, functions and activities of Contractor’s engineering
  organizations for AP1000 projects. Summarizes the interfaces, interactions
  and relationships with the rest of the AP1000 project organization. It does
  not contain detailed program descriptions or implementing procedures; rather,
  it references the detailed program descriptions and their respective
  implementing procedures.

  
	
   

  	
   

  	
   

  
	
  Project
  Completion and Closeout

  	
   

  	
  Identifies activities
  required to document completion of the Work. Identifies documentation
  required to document that a Unit has been delivered, constructed and tested
  in accordance with the terms of the Agreement and the deliverables have been
  provided and accepted by Owner, and all contract related commercial issues
  have been resolved.

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
2 of 4

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Process Title

  	
   

  	
  Process
  Description

  
	
   

  	
   

  	
   

  
	
  Project
  Controls Plan

  	
   

  	
  Describes the
  measurement, monitoring and forecasting methods for the change control
  process for schedule and cost with necessary approval and reporting.
  Describes the project controls to be utilized and describes the project
  controls organization and responsibilities. The cost controls area will also
  define the processes, procedures, roles, and responsibilities for how
  invoices and adjustments to invoices (i.e. escalation, contingency) will be
  submitted to Owner and how costs will be reported to Owner to fulfill FERC
  and South Carolina Public Service Commission requirements.

  
	
   

  	
   

  	
   

  
	
  System
  Turnover

  	
   

  	
  Establishes the
  requirements and responsibilities for the Turnover process from construction
  to startup. Define the scope and verification of Work completion for
  Contractor Turnover of a Unit to the Owner and its Operator.

  
	
   

  	
   

  	
   

  
	
  Start-up
  and Commissioning

  	
   

  	
  Describes test
  activities associated with Preoperational Test and Start-up Test programs.
  Defines test sequencing procedures and Level 3 test schedules. Defines roles
  and responsibilities, Site staff assumptions, and number of test personnel to
  achieve the test program. Lists Preoperational Test and Start-up Test ITAACs.
  Addresses interface with Turnover.

  
	
   

  	
   

  	
   

  
	
  Communication
  Plan

  	
   

  	
  Provide clear and
  effective formal Contractor communications, including information that
  affects schedule, engineering, construction, quality, procurement or
  contractual matters between Contractor and Owner, Subcontractors, and
  relevant third parties. Provide project documentation distribution matrix to
  Owner.

  
	
   

  	
   

  	
   

  
	
  Contract/Subcontract
  Management

  	
   

  	
  Describe how the
  contractual and financial requirements will be managed and executed between
  Owner and Contractor from execution of the Agreement to Final Completion.
  Includes the management of the agreement between the Consortium Members. Describes
  philosophy of flow down obligations and integration from the Consortium
  Members to their Subcontracts as specifically related to the Agreement.

  
	
   

  	
   

  	
   

  
	
  Regulatory/Licensing
  Management

  	
   

  	
  Identifies requirements
  and describes regulatory submittals and interactions with the NRC during each
  phase, pre-COLA application, COL support, ITAAC in planning, NRC oversight of
  procurement, fabrication and construction.

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
3 of 4

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Process Title

  	
   

  	
  Process
  Description

  
	
   

  	
   

  	
   

  
	
  AP1000
  Configuration Management

  	
   

  	
  Documents adherence to
  10 CFR Part 50, Appendix B in design and configuration control as the
  Work evolves from engineering through procurement, construction and Turnover.
  Documents general inter-organization processes for design and configuration
  management and control.

  
	
   

  	
   

  	
   

  
	
  AP1000
  Standardization Management

  	
   

  	
  Outline the reasons and
  benefits of domestic and international design standardization of the AP1000
  and establish limits for standardization.

  
	
   

  	
   

  	
   

  
	
  Resource
  Staffing Management

  	
   

  	
  Process to manage the
  project resources with emphasis on staffing. Necessary instructions to
  resource with competent individuals with the necessary training and
  qualifications to deliver a quality product. Controls will be specified to
  check individual qualifications and provide supplemental training for site
  activities.

  
	
   

  	
   

  	
   

  
	
  Information
  Management System

  	
   

  	
  Develop central
  database and “air traffic control” system using Smart Plant Foundation with
  links to the sources of information. Identify/document processes for
  populating, maintaining, delivering and accessing information. Define unique
  plant information technology infrastructure requirements needed for
  information management system to function.

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
4 of 4

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Exhibit E

Project
Schedule

 

The Project Schedule (and
any revisions thereto) is the Primavera schedule.

 

The Project Schedule for
construction of the Standard Plant is provided on the Attachment based on the
Full Notice to Proceed being received no later than [**].

 

[**] Contractor will
prepare and deliver to Owner a Site specific Project Schedule that will
incorporate the Site specific Work with a Site specific construction schedule
[**].  Both Parties will work together in
this Project Schedule change development [**].

 

Contractor shall perform
the Work under this Agreement in accordance with the Project Schedule.  The Project Schedule shall be updated
throughout the Contractor’s performance of the Work as necessary to meet the
following Milestones, as adjusted based on the Site specific Project Schedule
described above.

 

Critical
Milestones

 

[**]

 

[**]

 

[**]

 

[**]

 

[**]

 

[**]

 

[**]

 

[**]

 

[**]

 

Notes:

 

1.               [**]

2.               [**]

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to
a request for confidential treatment and filed separately with the Securities
and Exchange Commission.

 

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

[**A 25-page schedule to Exhibit E—Project
Schedule has been omitted in its entirety pursuant to a request for
confidential treatment and filed separately with the Securities and Exchange
Commission.**]

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to
a request for confidential treatment and filed separately with the Securities
and Exchange Commission.

 

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT F-1

Milestone Payment Schedule

 

This Exhibit F-1 provides the Payment Schedules for the
[**] portions of the Agreement.  These
payments will be invoiced in accordance with the provisions of Article 8
— Payments, Exhibit H - Pricing and Exhibit J- Price
Adjustment Provisions.

 

Capitalized terms used herein and not defined herein have the meaning
assigned in the Agreement.

 

The
Westinghouse Phase 1A work with a value of [**] and the Stone &
Webster Phase 1A Work with a value of [**] were paid under separate
agreements.  These amounts are included
in Exhibit H - Pricing but are not included in any of the below payment
schedule tables.

 

Milestone
Payment Schedules will be revisited, once the Project Schedule is completed, to
set the payments to the appropriate set of Milestones reflecting the Work
associated with the payments, by [**].

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 1 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

F.1           [**]

 

F.1.1        Westinghouse [**] Payments

 

	
  Estimated
  

  Invoice 

  Date

  	
  Component

  	
  Milestone

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Squib Valves

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  CMT

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  ACT

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCL Pipe

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  CRDMs

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  VFD

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  VFD

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  CMT

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  ACT

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCL Pipe

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 2 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Component

  	
  Milestone

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  [**]

  	
  Project

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  CRDMs

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  ACT

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  ACT

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Main
  Transformers

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Squib Valves

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  CMT

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  CMT

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Royalties

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 3 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Component

  	
  Milestone

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  CMT

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RCL Pipe

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RCL Pipe

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  CMT

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  CRDMs

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  CRDMs

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  ACT

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCL Pipe

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 4 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Component

  	
  Milestone

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  [**]

  	
  CRDMs

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  ACT

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  CRDMs

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  CMT

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RCL Pipe

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Allowance

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Allowance

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  CMT

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 5 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Component

  	
  Milestone

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  CMT

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  CRDMs

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Squib Valves

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  ACT

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  VFD

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  CRDMs

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Fuel Hand’l Mch

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Refueling Mach

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  CRDMs

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  VFD

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 6 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Component

  	
  Milestone

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  [**]

  	
  RV

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  ACT

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  ACT

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCL Pipe

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Fuel Hand’l Mch

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  CRDMs

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  CRDMs

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Refueling Mach

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  ACT

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  ACT

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 7 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Component

  	
  Milestone

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  [**]

  	
  Project

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Squib Valves

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  CRDMs

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  CRDMs

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Spt Fuel Strg
  Rack

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCL Pipe

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RCL Pipe

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  VFD

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 8 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Component

  	
  Milestone

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  [**]

  	
  CMT

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  CRDMs

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux-Res Xfmr

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Spt Fuel Strg
  Rack

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Spt Fuel Strg
  Rack

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Squib Valves

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Squib Valves

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  ACT

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  VFD

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  CMT

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux-Res Xfmr

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Squib Valves

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 9 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Component

  	
  Milestone

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  [**]

  	
  VFD

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  ACT

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Squib Valves

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Main
  Transformers

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  CRDMs

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  ACT

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 10 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Component

  	
  Milestone

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Squib Valves

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  CRDMs

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  CMT

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RCL Pipe

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  CMT

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Refueling Mach

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  VFD

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 11 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Component

  	
  Milestone

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  [**]

  	
  S/G

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  CMT

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Main
  Transformers

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Squib Valves

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Fuel Hand’l Mch

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Fuel Hand’l Mch

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Refueling Mach

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Spt Fuel Strg
  Rack

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  VFD

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Squib Valves

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 12 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Component

  	
  Milestone

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Spt Fuel Strg
  Rack

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Squib Valves

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux-Res Xfmr

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Main
  Transformers

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Aux-Res Xfmr

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 13 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Component

  	
  Milestone

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Spt Fuel Strg
  Rack

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Refueling Mach

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Main
  Transformers

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Fuel Hand’l Mch

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Fuel Hand’l Mch

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Refueling Mach

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Spt Fuel Strg
  Rack

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 14 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Component

  	
  Milestone

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Spt Fuel Strg
  Rack

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux-Res Xfmr

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Main
  Transformers

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux-Res Xfmr

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Spt Fuel Strg
  Rack

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 15 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

F.1.2        Westinghouse [**] Payments

 

	
  Estimated
  

  Invoice 

  Date

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  Apr-08

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  May-08

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jun-08

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jul-08

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Aug-08

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Sep-08

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Oct-08

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Nov-08

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Dec-08

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jan-09

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Feb-09

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Mar-09

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Apr-09

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  May-09

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jun-09

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jul-09

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Aug-09

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 16 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  Sep-09

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Oct-09

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Nov-09

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Dec-09

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jan-10

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Feb-10

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Mar-10

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Apr-10

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  May-10

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jun-10

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jul-10

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Aug-10

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Sep-10

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Oct-10

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Nov-10

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Dec-10

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jan-11

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Feb-11

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a request
for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 17 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  Mar-11

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Apr-11

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  May-11

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jun-11

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jul-11

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Aug-11

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Sep-11

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Oct-11

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Nov-11

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Dec-11

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jan-12

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Feb-12

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Mar-12

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Apr-12

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  May-12

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jun-12

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jul-12

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Aug-12

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 18 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  Sep-12

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Oct-12

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Nov-12

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Dec-12

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jan-13

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Feb-13

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Mar-13

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Apr-13

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  May-13

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jun-13

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jul-13

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Aug-13

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Sep-13

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Oct-13

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Nov-13

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Dec-13

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jan-14

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Feb-14

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 19 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  Mar-14

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Apr-14

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  May-14

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jun-14

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jul-14

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Aug-14

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Sep-14

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Oct-14

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Nov-14

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Dec-14

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jan-15

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Feb-15

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Mar-15

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Apr-15

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  May-15

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jun-15

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jul-15

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Aug-15

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 20 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  Sep-15

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Oct-15

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Nov-15

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Dec-15

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jan-16

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Feb-16

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Mar-16

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Apr-16

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  May-16

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jun-16

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jul-16

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Aug-16

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Sep-16

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Oct-16

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Nov-16

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Dec-16

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jan-17

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Feb-17

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 21 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  Mar-17

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Apr-17

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  May-17

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jun-17

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jul-17

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Aug-17

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Sep-17

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Oct-17

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Nov-17

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Dec-17

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jan-18

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Feb-18

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Mar-18

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Apr-18

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  May-18

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jun-18

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jul-18

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Aug-18

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 22 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  Sep-18

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Oct-18

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Nov-18

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Dec-18

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jan-19

  	
   

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 23 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

F.1.3        Westinghouse [**] Payments

 

	
  Estimated
  

  Invoice 

  Date

  	
  Component

  	
  Milestone
  Payment

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  [**]

  	
  RCP, SG, RV

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  VFD

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  VFD

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  CMT

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  CMT

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCL Pipe

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 24 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Component

  	
  Milestone
  Payment

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  [**]

  	
  T/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Fuel Hand’l Mch

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  T/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 25 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Component

  	
  Milestone
  Payment

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  [**]

  	
  VFD

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  VFD

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Pressurizer

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  ACT

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RV

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  IHP

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 26 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Component

  	
  Milestone
  Payment

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  [**]

  	
  Aux-Res Xfmr

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Main Transformers

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Passive RHR Hx

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RVI

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  S/G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Polar Crane

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCP

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux-Res Xfmr

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  I&C/Simulator

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Spt Fuel Strg Rack

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Rx Vessel

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 27 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated
  

  Invoice 

  Date

  	
  Component

  	
  Milestone
  Payment

  	
  Unit
  2 

  Invoice 

  Amount

  	
  Unit
  3 

  Invoice 

  Amount

  	
  Adjustment

  
	
  [**]

  	
  Containment Vessel

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Generator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Generator

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  TG Bldg

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Project

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 28 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

F.1.4        Stone & Webster [**] Milestone
Payments

 

Stone & Webster [**]

Payment Schedule

[**]

 

	
  Invoice
  

  Date

  	
  Payment

  
	
  Jul-08

  	
  [**]

  
	
  Oct-08

  	
  [**]

  
	
  Jan-09

  	
  [**]

  
	
  Apr-09

  	
  [**]

  
	
  Jul-09

  	
  [**]

  
	
  Oct-09

  	
  [**]

  
	
  Jan-10

  	
  [**]

  
	
  Apr-10

  	
  [**]

  
	
  Jul-10

  	
  [**]

  
	
  Oct-10

  	
  [**]

  
	
  Jan-11

  	
  [**]

  
	
  Apr-11

  	
  [**]

  
	
  Jul-11

  	
  [**]

  
	
  Oct-11

  	
  [**]

  
	
  Jan-12

  	
  [**]

  
	
  Apr-12

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 29 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

F.1.5        Stone & Webster [**] Milestone
Payment Schedule

 

Stone &
Webster [**]

Milestone
Payment Schedule

 

	
  Activity
  ID

  	
  Activity
  Name

  	
  Unit

  	
  Start

  	
  Payment
  Due

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
   

  	
  U2

  	
   

  	
   

  
	
   

  	
   

  	
  U3

  	
   

  	
   

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Contract Execution

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Contract Execution

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
30 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Stone &
Webster [**]

Milestone
Payment Schedule

 

	
  Activity
  ID

  	
  Activity
  Name

  	
  Unit

  	
  Start

  	
  Payment
  Due

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates material
that has been omitted pursuant to a request for confidential treatment and
filed separately with the Securities and Exchange Commission.

 

Page
31 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Stone &
Webster [**]

Milestone
Payment Schedule

 

	
  Activity
  ID

  	
  Activity
  Name

  	
  Unit

  	
  Start

  	
  Payment
  Due

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  U2 Milestone TBD

  	
  U2

  	
  [**]

  	
  [**]

  
	
   

  	
  U3 Milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  Unit 3 milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Cure Time for Nuclear
  Island Basemat

  	
  U2

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates material
that has been omitted pursuant to a request for confidential treatment and
filed separately with the Securities and Exchange Commission.

 

Page
32 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Stone &
Webster [**]

Milestone
Payment Schedule

 

	
  Activity
  ID

  	
  Activity
  Name

  	
  Unit

  	
  Start

  	
  Payment
  Due

  
	
  [**]

  	
  Aux Bldg - Begin
  Concrete Rebar Installation (Does Not Include CA20), EL 66’6

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Place Concrete for Unit
  2 Nuclear Island Basemat

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  Unit 3 milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin
  Installation of Aux Bldg Elevator, Clean & Dirty Sides, EL 66’6

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin
  Electrical Equipment Installation, EL 66’6 All Areas

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin
  Installation of Large Bore Piping , EL 66’6

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  Unit 3 milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin
  Concrete Fill of CA20 Structural Module, EL 66’6

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Place
  Concrete to EL 71’-6 & Containment Sump Curbs (KQ11)

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin
  Placement of Concrete, EL 82’6

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  Unit 3 milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin
  Installation of R251 SFS/WLS Commodity Module EL 82’6

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin
  Installation of Spent Fuel Pool Heat Exchangers, EL 82’-6

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Place
  Concrete Floor at Column Line 1-2, EL 82’6 Area 5 & 6

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  Unit 3 milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  ITAAC 3.3.11 - Concrete
  Over Soft Soil @ 84’

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Place
  Concrete Floor Slabs, EL 82’6 Area 1

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Building - Place
  Concrete Under Containment Vessel (CV), EL 74’6 to 82’6 Areas 7 & 8

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  Unit 3 milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin
  Installation of CA22 Floor Module, EL 82’6

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin
  Installation of Duct, EL 66’6

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin
  Installation of Standard Service Modules (KU), EL 66’6 Corridor Areas 3,
  4 & 5

  	
  U2

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
33 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Stone &
Webster [**]

Milestone
Payment Schedule

 

	
  Activity
  ID

  	
  Activity
  Name

  	
  Unit

  	
  Start

  	
  Payment
  Due

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  Unit 3 milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Concrete
  Cure for Condensate Trench Bottom Mat, EL 89’ Area 0

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Annex Bldg - Place Slab
  On Grade, Rooms 40311 & 40325 Column Lines 7.8 - 13 & A -
  E, EL 100’ Area 4

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Annex Bldg - Install
  Underground Plumbing Piping, Rooms 40326 - 40327& 40350 - 40357 EL 89’
  Area 4

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  Unit 3 milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Install
  Rebar for Circ Water (CWS) Trench Turbine Bldg - West Wall, EL 89’ Area 0

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Install Fire
  Protection Equipment, EL 82’6 - 100’

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Install
  Rebar for Circ Water (CWS) Trench North and South Walls, EL 89’ Area 0

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  Unit 3 milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Annex Bldg - Install
  Floor Drains, Piping & Embeds in Basemat, EL 89’ Areas 1,
  2 & 3

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment -
  Install & Connect Rebar Adjacent to Containment Vessel to 107’2,
  West Side

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Place
  Concrete (CWS) Trench Walls 89’ to 100’

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  Unit 3 milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Annex Bldg -
  Install & Connect Rebar For 2’ Wall at Col 9, E-H.03/6.5, EL 100’ -
  118’2 Areas 1 & 2

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Begin
  Installation of PXS Accumulator Tanks, EL 84’6

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Annex Bldg -
  Install & Connect Rebar for North Grade Wall at Column Line 4.1, EL
  100’ to 107’2 Areas 2 & 3

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  Unit 3 milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - #1
  Install and Connect Rebar for Turbine Bldg Basemat at Column Lines 18-20, EL
  100’, Area 3

  	
  U2

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
34 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Stone &
Webster [**]

Milestone
Payment Schedule

 

	
  Activity
  ID

  	
  Activity
  Name

  	
  Unit

  	
  Start

  	
  Payment
  Due

  
	
  [**]

  	
  Turbine Bldg - #4
  Install and Connect Rebar for Turbine Bldg Basemat at Column Line
  14-17 & Column Line I.2 - R, EL 100’

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Annex Bldg - Place East
  Grade Wall at Column Line E, EL 100’-107’2 Areas 2 & 3

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  Unit 3 milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Install
  KQ23 Upper Chemical Volume Control System (CVS) Module, EL 84’6
  Room 11209 Area 2

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Annex Bldg - Install
  Roof Ventilator VXS-MY-V02, EL 118’6 Area 4

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Place
  Mass Concrete to EL 107’2 with Curbs 108’-2 Northeast

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  Unit 3 milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment -
  Prepare & Prime Floors and Walls, EL 107’2 to 118’6

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Install
  T/G Support Module 2031-CH-81A

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Install
  Cable Trays & Supports EL 89’ to 100’ 0”

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  Unit 3 milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Erect
  Structural Steel at Column Line I.2-L.1 12.1-14, EL 116’9 -134’6 Area 4

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Annex Bldg -
  Install & Finish Plumbing Fixtures, EL 100’ Area 4

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  TURBINE BLDG -
  SET & INSTALL MONORAILS EL 117’ 6” to 135’ 3”

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  Unit 3 milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Annex Bldg - Install
  Lighting & Complete Electrical, EL 100’ Area 4

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Annex Bldg - Paint
  Piping, EL 100’Area 4

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin
  Preparation & Priming of Surfaces, EL 100’ to 117’6

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  Unit 3 milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  ERECT - HYDROGEN
  STORAGE TANK AREA

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg -
  Prepare & Prime Surfaces, EL 100’ to 117’6 Areas 5 & 6

  	
  U2

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
35 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Stone &
Webster [**]

Milestone
Payment Schedule

 

	
  Activity
  ID

  	
  Activity
  Name

  	
  Unit

  	
  Start

  	
  Payment
  Due

  
	
  [**]

  	
  Annex Bldg - Perform
  Piping Integrity Check, EL 100’ Area 2

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  Unit 3 milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg -
  Set & Install VFD’s EL 135’ 3” to 161’ 0”

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Place
  Concrete Slab above Grade (SAG) at Column Line K.1-P.1 & 12.1-14, EL
  117’6 Area 0

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Place
  Concrete Floor, EL 117’-6 Areas 5 & 6

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  Unit 3 milestone TBD

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Install
  Concrete Reinforcing Slab at EL 135’3

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Ground
  Structural Steel at Heater Bay, EL 100’

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Perform
  Piping Integrity Check, EL 66’-6 Areas 7 & 8

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  (EDS) TEST SWITCH
  BOARDS

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  (TCS) TEST PUMPS

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin
  Installation of Reinforcing Assemblies , EL 262’9 to 333’9

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Annex Bldg - Install
  Battery Room Exhaust Fan VXS-MA-09A & B, EL 135”3 Area 1

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Install
  High Pressure Turbine Cross Under Exhaust East & West Pipe Spool, EL
  100’ Area 1

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg -
  Form Deck Roof Slab at Column Line I-J1 & 2-4, EL 153’ Area 5

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Turbine Bldg - Install
  Turbine Lower casings, EL 161’-2 Area 1

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Install
  Grounding

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Install Nuclear Island
  Basemat Lower Rebar & Embeds

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Aux Bldg - Assemble
  Wall Rebar for EL 100’-135’3 Areas 1 - 8

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Install
  Piping Make Up Pieces to Auxiliary Boiler Equipment & Modules, El
  100’ Area 2

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  (IDS) TEST SWITCH
  BOARDS

  	
  U2

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
36 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Stone &
Webster [**]

Milestone
Payment Schedule

 

	
  Activity
  ID

  	
  Activity
  Name

  	
  Unit

  	
  Start

  	
  Payment
  Due

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Aux Bldg - Install
  Forms for Butting Wall J-2 & K-2 EL 66’-84’ Area 6

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin
  Installation of Concrete Forms, EL 66’6

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Place Concrete for Unit
  3 Nuclear Island Basemat

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Aux Bldg -
  Prepare & Prime Surfaces, EL 66’6 Area 4

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin
  Electrical Equipment Installation, EL 66’6 All Areas

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Perform
  Piping Integrity Check, EL 89’ & 100’ Area 0

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  (ASS) TEST CIRCUIT
  BREAKERS

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Install Wall
  Form at Column Line 9.5 From I to K, EL 66’6 - 84’6 Area 2

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  (CCS) TEST CIRCUIT
  BREAKERS

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Aux Bldg - Begin
  Installation of Wall Forms, EL 100’

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg -
  Pull & Terminate Cable, EL89’ & 100’ Area 9

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Install
  Instruments to Support Hydro Test, EL 66’6 to 82’6 Areas 1 & 2

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  (RNS) TEST CIRCUIT
  BREAKERS

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Install
  Rebar for Steam Generator Floors, EL 83’

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Install
  CB51 Steam Gen #1 Room Wall Panel Module (A), EL 80’-83’ Room 11201
  Areas 1 & 2

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  ECS ENERGIZE 4160V
  SWGEAR TURB EL 135’ A 7 14.

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Place
  Concrete to EL 87’ 6

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Begin
  Concrete Placement, EL 84’6 - 108’2

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  CWS - SYSTEM HYDRO
  TURB & YARD

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  CVS FLUSH P 1 W/TMP PMP
  THRU CVS SKID TO SF POOL

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Remove
  Bracing from CA04 Reactor Vessel Cavity / RCDT Structural

  	
  U3

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
37 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Stone &
Webster [**]

Milestone
Payment Schedule

 

	
  Activity
  ID

  	
  Activity
  Name

  	
  Unit

  	
  Start

  	
  Payment
  Due

  
	
   

  	
  Module, EL 87’6

  	
   

  	
   

  	
   

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  CCS HYDRO PKG A IN AUX
  BUILDING FROM 100’ to 135’3

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  FPS HYDRO PKG H AUX
  3,4,5,6 ABOVE 135’ & Above

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  (MSS) TEST RELIEF
  VALVES

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Aux Bldg - Begin
  Installation of Concrete Wall Forms, EL 118’6 - 133’

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Install Make
  Up Piping for Cradle Reinforcement South, EL 66’6 Area 7

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Place
  Concrete at Column Line North Wall Column Line 2 - 4, EL 89’ thru 98’1 Area 6

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  (CDS) TEST MOTOR
  HEATERS

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg -
  Flush & Hydro all Large Bore Pipe, By System, El All

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Aux Bldg - Place
  Concrete Floor Slabs, EL 82’6 Area 2

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Place
  Concrete Beams at Column Line 9.1 - 9.5, J & K to 81’-6

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Aux Bldg - Begin
  Installation of Degasifier Column, EL 74’6

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Annex Bldg - Excavate
  for Basemat (Check Soil Conductivity), EL 89’ Area 1A

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Annex Bldg - Install
  Basemat Grounding Grid, Column Lines 2 - 13 & A - I1, EL 89’ Areas
  1, 2, 3 & 4

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Annex Bldg - Install
  Masonry Wall Column Line C.5 Corridor Wall, Rooms 40311 & 40319, EL
  100’ - 118’ Area 4

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Aux Bldg - Begin
  Concrete Placement, EL 107’2

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Install
  Precast Panels, EL 100’ for Room 12351 Area 4

  	
  U3

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
38 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Stone &
Webster [**]

Milestone
Payment Schedule

 

	
  Activity
  ID

  	
  Activity
  Name

  	
  Unit

  	
  Start

  	
  Payment
  Due

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Aux Bldg - Begin
  Installation of Personnel Access Hatch from Aux Bldg to Containment, EL 107’2

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Install
  6” Work Mat below Turbine Bldg Basemat, EL 95’6 Area 0

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Annex Bldg - Cure 2’
  Wall at Column Line 9,E-H.03/6.5 Room 40309, EL 100’ Area 1

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Place
  Concrete Wall at Column I 7.3-10, EL 133’- 149’ Area 2

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Annex Bldg - Place 2’
  Wall at Col 12-13 & G.2-H.03 (Room 40305), EL 100’ - 117’2 Area
  1

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Turbine Bldg - #2 Place
  Turbine Bldg Basemat, Areas 8 & 9, EL 100’0

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg -
  Prepare & Prime Walls, EL 117’6 to 135’3 Areas 7 And 8

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Install
  Shield Wall Form at 5-N EL 165’-181’ Areas 7 & 8

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Annex Bldg - Install
  Forms East Grade Wall Col. Line E, Rooms 40326, 40353, 40357, 40340, EL 100’
  - 107’2 Areas 2 & 3

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - #5 Place
  Turbine Bldg Basemat at Column Line 11-12.1, EL 100’

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Annex Bldg - Install
  Roof Ventilator VXS-MY-V02, EL 118’6 Area 4

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Turbine Bldg - Install
  CH81C North Turbine Turning Gear (TG)Support Module 2033-CH81C, EL 100’ Area
  3

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Annex Bldg - Install
  Forms for Area 1, EL 117’6

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Aux Bldg - Place Concrete
  Shield Wall at Column 5-Q EL 179’ - 213’ Areas 7 & 8

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Annex Bldg - Install
  Forms for 1’ Wall at Column Line 4 E-H, EL 120’ To 134’ Areas 2 & 3

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Install
  Cable Trays & Supports EL 117’ 6” to 135’ 3”

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Turbine Bldg - Ground
  Structural Steel at Column Line 12-14, EL 100’

  	
  U3

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
39 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Stone &
Webster [**]

Milestone
Payment Schedule

 

	
  Activity
  ID

  	
  Activity
  Name

  	
  Unit

  	
  Start

  	
  Payment
  Due

  
	
  [**]

  	
  ECS ENERGIZE MCC’S
  132/232 TEMP POW AUX 100’

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Install
  Ring #2 Including Walkway, Horizontal CircularTray and Piping, EL 135’3

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Annex Bldg - Install 5
  Ton Crane and Hook Column Line 2 - 4 & G - H Room 40358, EL
  107’2 Area 3

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Place
  Concrete Slab above Grade (Slab above Grade (SAG)) at I.2-K.1 &
  12.1-14, EL 117’-6 Area 4

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Annex Bldg - 1D, Cure
  2’ Wall at Column Line 9, E-H.03/6.5

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Annex Bldg - Install
  Exhaust Fans (VBS/VXS-MA-09/13), EL 135’3 Area 1

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Install
  Lighting Transformers, EL 100’ Area 0

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Install
  Structural Steel Roof Framing & Deck, EL 160’ Areas 3 & 4

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Containment -
  Align & Tack Structural Modules CA02, CA03, & CA56, EL 84’6
  - 135’3

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Install
  Lower (CDS) Condenser Shell C, El 100’ Area 2

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Install CH67
  Upper Annulus Stair/Lift Platform, EL 243’ to 261

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Turbine Bldg - Install
  KT04 Service Water System (SWS) Strainer Module, EL 100’ Area 0

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Install
  Conduit, EL 153’ to 264’-6”

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Aux Bldg - Install
  Valves, EL 117’6 to 135’3

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Annex Bldg - Install
  Elevator Mechanical Equipment, EL 180’ Areas 2 & 3

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Install
  Cable Tray Along Column Line R 13.1-17, EL 99’ Area 1

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Turbine Bldg - Install
  W480 Feedwater (FWS)Booster Pump Suction Pipe Module, EL 117’6 Area 8

  	
  U3

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
40 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Stone &
Webster [**]

Milestone
Payment Schedule

 

	
  Activity
  ID

  	
  Activity
  Name

  	
  Unit

  	
  Start

  	
  Payment
  Due

  
	
  [**]

  	
  Annex Bldg - Perform
  Construction Pre - Turnover Electrical Check Out, EL 107’-2 Area 2

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Fitup
  Circ Water System (CWS) Supply & Return Piping to the Condenser, EL
  100’ Area 2

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Turbine
  Building-INSTALL MODULE W581-South Heater Bay Vertical Pipe Chase

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Install
  Piping from Condensate Pump Discharge to CPS Equipment Package, EL 100’ Area
  6

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Turbine Bldg - Install
  KT48 VYS Module, EL 117’-6 Area 8

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine
  Building-INSTALL MODULE KT34-LOS Clean Oil Transfer Pump Module

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Install
  W680 Feedwater (FWS) Min-Flow Pipe Module, EL 135 Area 8

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin
  Construction Testing (Hot & Cold Checks) of Electrical Components,
  EL 66’-6

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Turbine Bldg - Install
  Dike Wall at Column Lines 12.1-13.1 & P.1-R in LOS Room, EL 117’-6

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Turbine Bldg - Perform
  Piping Integrity Check, EL 161’ Area 9

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Install EDS
  Batteries in Division B Battery Room 12204, EL 82’-6 Area 1

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Pull
  Cable from MCC’S on EL 117’6 to all Areas, EL 100’

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin Piping
  Integrity Checks, EL 135’-3

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Aux Bldg - Charge EDS
  Batteries

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  (RWS) TEST CIRCUIT
  BREAKERS

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RNS HYDRO PKG B FROM
  PUMP DISC TO ISO VALVE

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  ECS ELECTR CHECK OUT
  MCC’S 312/313 TURB 117’

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Yard -
  Excavate & Install Underground Diesel Fuel Lines

  	
  U3

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
41 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Stone &
Webster [**]

Milestone
Payment Schedule

 

	
  Activity
  ID

  	
  Activity
  Name

  	
  Unit

  	
  Start

  	
  Payment
  Due

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  (IDS) TEST SWITCH
  BOARDS

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  (IDS) TEST FUSE PANELS

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  ECS ENERGIZE LOAD
  CENTRS TURB 135’ A 7

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  UNIT 2 Substantial
  Completion

  	
  U2

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Turbine Bldg - Perform
  Piping Integrity Check, EL 135’-3 Area 5

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Perform
  Piping Integrity Check, EL 135’-3 Area 0

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Install
  CA31 Steel Floor, EL 107’2 Reactor Vessel Cavity Floor Module (11105 Ceiling,
  Floor 11504)

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  RNS - HYDRO PKG B FM
  IRWST/CVS 7&8 TO RNS PUMPS

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  (VWS) TEST PUMP MOTORS

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Install
  Fire Protection Equipment, EL 135’3

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Aux Bldg - Install WLS
  PDT-160 Waste After Filter Differential Pressure Transmitter, EL 66’6
  Room 12151 Area 4

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin
  Installation of Instrumentation in all Rooms, EL 66’6 to 82’6

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Perform
  Piping Integrity Check, EL 118’6 - 135’3

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Annex Bldg - Pull
  Cable & Terminate, EL 117’ Area 1

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Perform
  Piping Integrity Check, EL 117’-6 Area 3

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  (DWS) TEST CIRCUIT
  BREAKERS

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Radwaste Bldg - Pull
  Cable, Room 50353, EL 100’ Area 3

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  (RNS) TEST PUMP MOTORS

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Pull
  Cable & Terminate ,EL 117’6 Area 1

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Turbine Bldg - Perform
  Pre - Turnover Construction Electrical Check Out, EL 117’-6 Area 3

  	
  U3

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
42 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Stone &
Webster [**]

Milestone
Payment Schedule

 

	
  Activity
  ID

  	
  Activity
  Name

  	
  Unit

  	
  Start

  	
  Payment
  Due

  
	
  [**]

  	
  Aux Bldg - Activate
  Class 1E DC and UPS System (IDS) A/B/D DK-1 to RNS Isolation Valve
  Control Power

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Pull
  Cable from MCC’S on EL 117’ to all Areas EL 135’3

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  FPS HYDRANT
  FLUSH & PRESSURE TEST

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Perform
  Testing of Polar Crane (MHS-MH-01), EL 135’3 Area 1

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg -
  Pull & Terminate Cable, EL 135’-3 Area 4

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Diesel Gen Bldg - Pull
  Cable & Terminate - Drain Sump Pump (WWS-MP-B), EL 100 Area 2

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Perform
  Construction Testing (Hot & Cold Checks) of Electrical Components,
  EL 84’6 to 107’2

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Perform
  Piping Integrity Check, EL 162’1 & above

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Containment - Install
  Balance of Piping Insulation (as required), EL 66’6 to 71’6 All Areas

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin
  Installation ofl Balance of Piping Insulation after Hydro, EL EL 135’3 to
  153’

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Perform
  Piping Integrity Check, EL 135’-3 Area 2

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Turbine Bldg - Activate
  Switchgear & Electrical Rooms, EL 135’-3

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Install
  KU05AZ Standard Service Module South, EL 135’3 Room 11500 Area 1

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Turbine Bldg - Perform
  Piping Integrity Check, EL 226’ Area 4

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  VYS HYDRO PKG D TURB
  PIPING ABOVE 117’ TO 161’

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Install
  Piping & Equipment Insulation (as required), EL 135’3 to 162’1 All
  Areas

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Perform
  Construction Testing (Hot & Cold Checks) of Electrical Components,
  EL 135’3

  	
  U3

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
43 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Stone &
Webster [**]

Milestone
Payment Schedule

 

	
  Activity
  ID

  	
  Activity
  Name

  	
  Unit

  	
  Start

  	
  Payment
  Due

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Aux Bldg - Complete
  Make Up Piping, EL 298’9 Room 12703 Areas 7 & 8

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  (MTS) TEST MAIN
  TURBINES

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Perform
  Piping Integrity Check, EL 258’ Area 7 Annulus

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Turbine Bldg - Perform
  Pre - Turnover Construction Electrical Check Out, EL 135’-3 Area 2

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  (PSS) TEST PUMP MOTORS

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Radwaste Bldg -
  Flush & Hydro all Large Bore Pipe, By System, El All

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Aux Bldg - Perform
  Construction Testing (Hot & Cold Checks) of Electrical Components,
  EL 100’ Areas 7 and 8

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin
  Activation of AC & DC Power to Plant Equipment, EL 135’3

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Begin
  Construction Testing (Hot & Cold Checks) of Electrical Components,
  EL 117’6

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  RXS VERIFY ROD CONTROL
  INTERLOCK AND SIGNAL

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RXS COMP
  FILL & VENT RV & PRESSURIZE PIPE

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Aux Bldg - Perform
  Normal Residual Heat Removal (RNS) Electrical System Checkout

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Turbine Bldg -
  Pull & Terminate Cable, EL 135’-3 Area 7

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Perform
  Communication System (Paging Only) Phase I Testing

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  LOS - VERIFY
  PERFORMANCE TURBINE ON TURNING GEAR

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Turbine Bldg - Perform
  Construction Electrical Checkout (Hot & Cold Checks), EL 100’ Areas
  3 & 7

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Install
  Reactor Vessel (RV) Head to Support Cold Hydro

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  (TDS) TEST CIRCUIT
  BREAKERS

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  (VES) TEST RELIEF
  VALVES

  	
  U3

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
44 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Stone &
Webster [**]

Milestone
Payment Schedule

 

	
  Activity
  ID

  	
  Activity
  Name

  	
  Unit

  	
  Start

  	
  Payment
  Due

  
	
  [**]

  	
  CDS FLUSH PKG 1 TURBINE
  BUILDING BELOW 135’

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  (PGS) TEST PUMP

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  (DRS) TEST STORM DRAIN
  SYSTEM (MECH)

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  (RDS) TEST
  GRAVITY & ROOF DRAINAGE SYSTEM

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  CDS - HYDRO PKG B TURB
  BUILDING ABOVE 135’

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Align
  Primary & Secondary Systems for Cold Hyro/Establish Pre-requisites

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  Containment - Install
  TE121A RCS Cold Leg 1A Narrow Range RTD 1, EL 104’ Room 11201

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  BDS-14.2.8.1.54 DRN SG
  S AFTER 2NDRY HYDRO

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Begin
  Installation of RCS Main Loop Instrumentation, EL 84’6

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  MTS TURBINE ROLL

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCS 14.2.8.1.67 VER
  OPERATION RCS 240 HRS (HFT)

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  Containment - Install
  Balance of Piping & Equipment Insulation after Hydro, EL 118’6 to
  135’3

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  VUS ISO VALVE ALIGNMENT
  COMPLETE

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  VUS 14.2.8.1.102 ILRT -
  CONTAINMENT VESSEL

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  VUS 14.2.8.1.93 SIT -
  CONTAINMENT VESSEL

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  No Milestones available

  	
   

  	
   

  	
   

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  No Milestones available

  	
   

  	
   

  	
   

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  No Milestones available

  	
   

  	
   

  	
   

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  READY FOR FUEL LOAD -
  UNIT 3

  	
  U3

  	
   

  	
   

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  INITIAL CRITICALITY &
  LPPT Unit 3

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  RCS HEATUP &
  RESOLVE HFT PUNCH LIST ITEMS

  	
  U3

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
45 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Stone &
Webster [**]

Milestone
Payment Schedule

 

	
  Activity
  ID

  	
  Activity
  Name

  	
  Unit

  	
  Start

  	
  Payment
  Due

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  ESCALATE TO 10% SYNCH
  ON GRID

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  POWER ASCENSION TO
  5%-SECONDARY SIDE WORK

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  MAINTENANCE OUTAGE

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  50% POWER TESTING

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  POWER ASCENSION TO 30%
  POWER

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  LOSS OF OFFSITE POWER
  TEST

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  LOAD SWING TESTING

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  100% POWER TESTING

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  [**] PERFORMANCE TEST
  Unit 3

  	
  U3

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  UNIT 3 Substantial
  Completion

  	
  U3

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
46 of 46

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT F-2

PAYMENT PLAN

 

Exhibit F-2 provides the [**] Scope of Work.  These payments will be invoiced in accordance
with the provisions of Article 8 — Payments, Exhibit H -
Pricing and Exhibit J- Price Adjustment Provisions.

 

Capitalized terms
used herein and not defined herein have the meaning assigned in the Agreement.

 

F.2           [**]

 

F.2.1        Westinghouse [**] Payments

 

	
  Estimated

  Invoice

  	
  Unit
  2

  	
  Unit
  3

  	
   

  
	
  Date

  	
  Material

  	
  Labor

  	
  Material

  	
  Labor

  	
  [**]

  
	
  Apr-08

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  May-08

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  Jun-08

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  Jul-08

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  Aug-08

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  Sep-08

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  Oct-08

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  Nov-08

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  Dec-08

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  Jan-09

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  Feb-09

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  Mar-09

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  Apr-09

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  May-09

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  Jun-09

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  Jul-09

  	
   

  	
  [**]

  	
   

  	
   

  	
  [**]

  
	
  Aug-09

  	
   

  	
  [**]

  	
   

  	
   

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
1 of 13

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated

  Invoice

  	
  Unit
  2

  	
  Unit
  3

  	
   

  
	
  Date

  	
  Material

  	
  Labor

  	
  Material

  	
  Labor

  	
  [**]

  
	
  Sep-09

  	
   

  	
  [**]

  	
   

  	
   

  	
  [**]

  
	
  Oct-09

  	
   

  	
  [**]

  	
   

  	
   

  	
  [**]

  
	
  Nov-09

  	
   

  	
  [**]

  	
   

  	
   

  	
  [**]

  
	
  Dec-09

  	
   

  	
  [**]

  	
   

  	
   

  	
  [**]

  
	
  Jan-10

  	
   

  	
  [**]

  	
   

  	
   

  	
  [**]

  
	
  Feb-10

  	
   

  	
  [**]

  	
   

  	
   

  	
  [**]

  
	
  Mar-10

  	
   

  	
  [**]

  	
   

  	
   

  	
  [**]

  
	
  Apr-10

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  May-10

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Jun-10

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Jul-10

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Aug-10

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Sep-10

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Oct-10

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Nov-10

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Dec-10

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Jan-11

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Feb-11

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Mar-11

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Apr-11

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  May-11

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jun-11

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jul-11

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Aug-11

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Sep-11

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Oct-11

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
2 of 13

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated

  Invoice

  	
  Unit
  2

  	
  Unit
  3

  	
   

  
	
  Date

  	
  Material

  	
  Labor

  	
  Material

  	
  Labor

  	
  [**]

  
	
  Nov-11

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Dec-11

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Jan-12

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Feb-12

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Mar-12

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Apr-12

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  May-12

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Jun-12

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Jul-12

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Aug-12

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Sep-12

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Oct-12

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Nov-12

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Dec-12

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Jan-13

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Feb-13

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Mar-13

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Apr-13

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  May-13

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Jun-13

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Jul-13

  	
  [**]

  	
   

  	
   

  	
  [**]

  	
  [**]

  
	
  Aug-13

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Sep-13

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Oct-13

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Nov-13

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Dec-13

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
3 of 13

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated

  Invoice

  	
  Unit 2

  	
  Unit 3

  	
   

  
	
  Date

  	
  Material

  	
  Labor

  	
  Material

  	
  Labor

  	
  [**]

  
	
  Jan-14

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Feb-14

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Mar-14

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Apr-14

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  May-14

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jun-14

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jul-14

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Aug-14

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Sep-14

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Oct-14

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Nov-14

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Dec-14

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jan-15

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Feb-15

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Mar-15

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Apr-15

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  May-15

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jun-15

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jul-15

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Aug-15

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Sep-15

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Oct-15

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Nov-15

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Dec-15

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jan-16

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Feb-16

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
4 of 13

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated

  Invoice

  	
  Unit 2

  	
  Unit 3

  	
   

  
	
  Date

  	
  Material

  	
  Labor

  	
  Material

  	
  Labor

  	
  [**]

  
	
  Mar-16

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Apr-16

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  May-16

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jun-16

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jul-16

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Aug-16

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Sep-16

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Oct-16

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Nov-16

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Dec-16

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Jan-17

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Feb-17

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Mar-17

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Apr-17

  	
   

  	
   

  	
  [**]

  	
   

  	
  [**]

  
	
  May-17

  	
   

  	
   

  	
  [**]

  	
   

  	
  [**]

  
	
  Jun-17

  	
   

  	
   

  	
  [**]

  	
   

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
5 of 13

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

F.2.2        Westinghouse [**]

Payments

 

	
  Estimated

  Invoice

  Date

  	
  Unit
  2

  	
  Unit
  3

  
	
  Apr-08

  	
   

  	
   

  
	
  May-08

  	
   

  	
   

  
	
  Jun-08

  	
   

  	
   

  
	
  Jul-08

  	
   

  	
   

  
	
  Aug-08

  	
   

  	
   

  
	
  Sep-08

  	
   

  	
   

  
	
  Oct-08

  	
   

  	
   

  
	
  Nov-08

  	
   

  	
   

  
	
  Dec-08

  	
   

  	
   

  
	
  Jan-09

  	
   

  	
   

  
	
  Feb-09

  	
   

  	
   

  
	
  Mar-09

  	
   

  	
   

  
	
  Apr-09

  	
   

  	
   

  
	
  May-09

  	
   

  	
   

  
	
  Jun-09

  	
   

  	
   

  
	
  Jul-09

  	
   

  	
   

  
	
  Aug-09

  	
   

  	
   

  
	
  Sep-09

  	
   

  	
   

  
	
  Oct-09

  	
  [**]

  	
   

  
	
  Nov-09

  	
  [**]

  	
   

  
	
  Dec-09

  	
  [**]

  	
   

  
	
  Jan-10

  	
  [**]

  	
   

  
	
  Feb-10

  	
  [**]

  	
   

  
	
  Mar-10

  	
  [**]

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
6 of 13

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated

  Invoice

  Date

  	
  Unit 2

  	
  Unit 3

  
	
  Apr-10

  	
  [**]

  	
   

  
	
  May-10

  	
  [**]

  	
   

  
	
  Jun-10

  	
  [**]

  	
   

  
	
  Jul-10

  	
  [**]

  	
   

  
	
  Aug-10

  	
  [**]

  	
   

  
	
  Sep-10

  	
  [**]

  	
   

  
	
  Oct-10

  	
  [**]

  	
   

  
	
  Nov-10

  	
  [**]

  	
   

  
	
  Dec-10

  	
  [**]

  	
   

  
	
  Jan-11

  	
  [**]

  	
   

  
	
  Feb-11

  	
  [**]

  	
   

  
	
  Mar-11

  	
  [**]

  	
   

  
	
  Apr-11

  	
  [**]

  	
   

  
	
  May-11

  	
  [**]

  	
   

  
	
  Jun-11

  	
  [**]

  	
   

  
	
  Jul-11

  	
  [**]

  	
   

  
	
  Aug-11

  	
  [**]

  	
   

  
	
  Sep-11

  	
  [**]

  	
   

  
	
  Oct-11

  	
  [**]

  	
   

  
	
  Nov-11

  	
  [**]

  	
   

  
	
  Dec-11

  	
  [**]

  	
   

  
	
  Jan-12

  	
  [**]

  	
   

  
	
  Feb-12

  	
  [**]

  	
   

  
	
  Mar-12

  	
  [**]

  	
   

  
	
  Apr-12

  	
  [**]

  	
   

  
	
  May-12

  	
  [**]

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
7 of 13

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated

  Invoice

  Date

  	
  Unit 2

  	
  Unit 3

  
	
  Jun-12

  	
  [**]

  	
   

  
	
  Jul-12

  	
  [**]

  	
   

  
	
  Aug-12

  	
  [**]

  	
   

  
	
  Sep-12

  	
  [**]

  	
   

  
	
  Oct-12

  	
   

  	
  [**]

  
	
  Nov-12

  	
   

  	
  [**]

  
	
  Dec-12

  	
   

  	
  [**]

  
	
  Jan-13

  	
   

  	
  [**]

  
	
  Feb-13

  	
  [**]

  	
  [**]

  
	
  Mar-13

  	
  [**]

  	
  [**]

  
	
  Apr-13

  	
  [**]

  	
  [**]

  
	
  May-13

  	
  [**]

  	
  [**]

  
	
  Jun-13

  	
  [**]

  	
  [**]

  
	
  Jul-13

  	
  [**]

  	
  [**]

  
	
  Aug-13

  	
  [**]

  	
  [**]

  
	
  Sep-13

  	
  [**]

  	
  [**]

  
	
  Oct-13

  	
  [**]

  	
  [**]

  
	
  Nov-13

  	
  [**]

  	
  [**]

  
	
  Dec-13

  	
  [**]

  	
  [**]

  
	
  Jan-14

  	
  [**]

  	
  [**]

  
	
  Feb-14

  	
  [**]

  	
  [**]

  
	
  Mar-14

  	
  [**]

  	
  [**]

  
	
  Apr-14

  	
  [**]

  	
  [**]

  
	
  May-14

  	
  [**]

  	
  [**]

  
	
  Jun-14

  	
  [**]

  	
  [**]

  
	
  Jul-14

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
8 of 13

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated

  Invoice

  Date

  	
  Unit 2

  	
  Unit 3

  
	
  Aug-14

  	
  [**]

  	
  [**]

  
	
  Sep-14

  	
  [**]

  	
  [**]

  
	
  Oct-14

  	
  [**]

  	
   

  
	
  Nov-14

  	
  [**]

  	
   

  
	
  Dec-14

  	
  [**]

  	
   

  
	
  Jan-15

  	
  [**]

  	
   

  
	
  Feb-15

  	
  [**]

  	
   

  
	
  Mar-15

  	
  [**]

  	
   

  
	
  Apr-15

  	
  [**]

  	
   

  
	
  May-15

  	
  [**]

  	
   

  
	
  Jun-15

  	
  [**]

  	
   

  
	
  Jul-15

  	
  [**]

  	
   

  
	
  Aug-15

  	
  [**]

  	
   

  
	
  Sep-15

  	
  [**]

  	
   

  
	
  Oct-15

  	
  [**]

  	
   

  
	
  Nov-15

  	
  [**]

  	
   

  
	
  Dec-15

  	
  [**]

  	
   

  
	
  Jan-16

  	
  [**]

  	
   

  
	
  Feb-16

  	
  [**]

  	
   

  
	
  Mar-16

  	
  [**]

  	
   

  
	
  Apr-16

  	
   

  	
   

  
	
  May-16

  	
   

  	
   

  
	
  Jun-16

  	
   

  	
   

  
	
  Jul-16

  	
   

  	
  [**]

  
	
  Aug-16

  	
   

  	
  [**]

  
	
  Sep-16

  	
   

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
9 of 13

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated

  Invoice

  Date

  	
  Unit 2

  	
  Unit 3

  
	
  Oct-16

  	
   

  	
  [**]

  
	
  Nov-16

  	
   

  	
  [**]

  
	
  Dec-16

  	
   

  	
  [**]

  
	
  Jan-17

  	
   

  	
  [**]

  
	
  Feb-17

  	
   

  	
  [**]

  
	
  Mar-17

  	
   

  	
  [**]

  
	
  Apr-17

  	
   

  	
  [**]

  
	
  May-17

  	
   

  	
  [**]

  
	
  Jun-17

  	
   

  	
  [**]

  
	
  Jul-17

  	
   

  	
  [**]

  
	
  Aug-17

  	
   

  	
  [**]

  
	
  Sep-17

  	
   

  	
  [**]

  
	
  Oct-17

  	
   

  	
  [**]

  
	
  Nov-17

  	
   

  	
  [**]

  
	
  Dec-17

  	
   

  	
  [**]

  
	
  Jan-18

  	
   

  	
  [**]

  
	
  Feb-18

  	
   

  	
  [**]

  
	
  Mar-18

  	
   

  	
  [**]

  
	
  Apr-18

  	
   

  	
  [**]

  
	
  May-18

  	
   

  	
  [**]

  
	
  Jun-18

  	
   

  	
  [**]

  
	
  Jul-18

  	
   

  	
  [**]

  
	
  Aug-18

  	
   

  	
  [**]

  
	
  Sep-18

  	
   

  	
  [**]

  
	
  Oct-18

  	
   

  	
  [**]

  
	
  Nov-18

  	
   

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
10 of 13

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Estimated

  Invoice

  Date

  	
  Unit 2

  	
  Unit 3

  
	
  Dec-18

  	
   

  	
  [**]

  
	
  Jan-19

  	
   

  	
   

  
	
  Feb-19

  	
   

  	
   

  
	
  Mar-19

  	
   

  	
   

  
	
  Apr-19

  	
   

  	
   

  
	
  May-19

  	
   

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
11 of 13

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

F.2.3        [**] Estimated Cash Flow

 

[**]
Estimated Quarterly Cash Flows [**]

 

	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  	
  [**]

  
	
  Calendar

  Quarter

  	
  Unit 2 &

  Common

  	
  Unit 3

  	
   

  	
  Unit 2 &

  Common

  	
  Unit 3

  	
   

  	
  Unit 2 &

  Common

  	
  Unit 3

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  Q1-08

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q2-08

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q3-08

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q4-08

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q1-09

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q2-09

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q3-09

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q4-09

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q1-10

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q2-10

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q3-10

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q4-10

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q1-11

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q2-11

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q3-11

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q4-11

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q1-12

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q2-12

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q3-12

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q4-12

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q1-13

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q2-13

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q3-13

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q4-13

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q1-14

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q2-14

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q3-14

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q4-14

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q1-15

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q2-15

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q3-15

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q4-15

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q1-16

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q2-16

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q3-16

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q4-16

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q1-17

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q2-17

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
12 of 13

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

[**]Estimated
Quarterly Cash Flows [**]

 

	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  	
  [**]

  
	
  Calendar

  Quarter

  	
  Unit 2 &

  Common

  	
  Unit 3

  	
   

  	
  Unit 2 &

  Common

  	
  Unit 3

  	
   

  	
  Unit 2 &

  Common

  	
  Unit 3

  
	
  Q3-17

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q4-17

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q1-18

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q2-18

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q3-18

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q4-18

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q1-19

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  
	
  Q2-19

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  

 

Notes:

1.               Cash flow forecast is preliminary is
subject to adjustment as the project progresses.

2.               Cash flow forecast includes estimated
contingency and profit.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
13 of 13

 

	
  Execution
  Version

  	
  Confidential Trade Secret Information—Subject to
  Restricted Procedures

  

 

EXHIBIT G

Time And
Material And Target Price Rates And Charges

 

For any portions of the
Contract Price to be paid to Westinghouse and Stone and Webster on a Time and
Materials Basis and Target Price Basis, the charges set forth in Section G.1
and G.2 respectively will apply.

 

G.1                             WESTINGHOUSE TIME AND MATERIALS
AND TARGET PRICE RATES AND CHARGES

 

For any portion of the
Contract Price to be paid to Westinghouse on a Time and Materials Basis, the
charges set forth in this Section G.1 will apply.

 

The Westinghouse hourly
rates for Time and Materials Work are provided in G.1.1 and G.1.2 below.  These established labor rates and the daily
per diem rate have a Base Date of [**] and will be subject to adjustment per Exhibit J.

 

G.1.1                      Westinghouse Time and Materials and
Target Price Rates and Charges for Base Scope of Work as of the Effective Date

 

The following rates in
Table G-1 will be used for the conditions described below.  In all other cases the rates in Table G-2 and
Section G.1.2 will be used.

 

a.               [**]

 

b.              [**]

 

c.               Import duties will [**].

 

d.              [**]

 

Table G-1

[**]

 

	
  Description

  	
  Billing rate

  
	
  Advisory Engineer

  	
  [**]

  
	
  QA Engineer

  	
  [**]

  
	
  I&C Sr. Engineer

  	
  [**]

  
	
  Senior Engineer

  	
  [**]

  
	
  Engineer

  	
  [**]

  
	
  Technician

  	
  [**]

  
	
  Per Diem (see G.1.2.b)

  	
  [**]

  
	
  Travel Expenses

  	
  [**]

  
	
  All other costs

  	
  [**]

  

 

[**]

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

Page 1 of 5

 

	
  Execution
  Version

  	
  Confidential Trade Secret Information—Subject to
  Restricted Procedures

  

 

G.1.2                      Time and Materials Work and Target Price
Rates and Charges for Changes in Scope

 

[**]

 

Table G-2

[**]

 

	
  Personnel
  Category

  	
  Billing Rate/hr

  
	
   

  	
   

  
	
  NSSS/I&C
  Engineering Services

  	
   

  
	
  Senior Manager,
  Chief Engineer, Consulting Engineer

  	
  [**]

  
	
  Fellow Engineer,
  Manager, Program Manager

  	
  [**]

  
	
  Consulting
  Technologist, Project Manager

  	
  [**]

  
	
  Principal
  Engineer, Senior Engineer, Project Engineer

  	
  [**]

  
	
  Engineer

  	
  [**]

  
	
  Technician/Draftsman

  	
  [**]

  
	
  Administrative
  Assistant

  	
  [**]

  
	
   

  	
   

  
	
  Mechanical
  Equipment Parts Engineering Service

  	
   

  
	
  Senior Manager,
  Consulting Engineer

  	
  [**]

  
	
  Fellow Engineer,
  Manager

  	
  [**]

  
	
  Consulting
  Technologist

  	
  [**]

  
	
  Principal
  Engineer, Senior Engineer

  	
  [**]

  
	
  Engineer

  	
  [**]

  
	
  Technician/Draftsman

  	
  [**]

  
	
  Administrative
  Assistant

  	
  [**]

  
	
   

  	
   

  
	
  Nuclear Field
  Services

  	
   

  
	
  Field Service
  Advisor (non-supervisory role)

  	
  [**]

  

 

[**]

 

a.                                       [**]

 

a.1                           The billing rate applies to all hours
worked, including work at the Site, unless otherwise authorized by Owner.

 

a.2                                 [**]

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

Page 2 of 5

 

	
  Execution
  Version

  	
  Confidential Trade Secret Information—Subject to
  Restricted Procedures

  

 

a.3                                 Travel time will include all time spent
traveling between the individual’s home location and the assigned work
location. [**]

 

b.                                      EXPENSES

 

Travel and living expenses, including any
expenses incurred during the period spent at the assigned work location such as
lodging, meals and incidental expenses, will be billed [**].  Round trip air fare and ground
transportation, including use of personal car, will be [**].

 

If Owner requires that Westinghouse bill
living expenses [**] and requires copies of detailed supporting receipts for
travel and living expenses, [**].

 

[**]

 

c.                                       OTHER
CHARGES

 

Non-Westinghouse
Equipment/Material and Other Services/Charges

 

Material, including
non-Westinghouse service equipment, leased or purchased by Westinghouse for
Owner in the performance of Work rendered hereunder will be invoiced [**].

 

If Westinghouse
subcontracts for services which are not normally provided by Westinghouse,
[**].

 

[**]

 

Cost of insurances, bonds
or other security instruments shall be billed [**].

 

d.                                      HOLIDAY PREMIUM

 

[**]

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

Page 3 of 5

 

	
  Execution
  Version

  	
  Confidential Trade Secret Information—Subject to
  Restricted Procedures

  

 

e.                                       TERMS
OF PAYMENT

 

Terms of payment shall be as set forth in
Article 8 of this Agreement.

 

f.                                         STAFF
AUGMENTATION SERVICES, CREW RATES OR PERSONNEL ON LONG TERM ASSIGNMENT

 

[**]

 

g.                                      PERSONNEL
DEFINITIONS

 

“NSSS/I&C Engineering Services”
consist of those services requiring the resources, capabilities and
technological application associated with the design of the Nuclear Steam
Supply System including the reactor and safety related design systems.  These services include the design, analysis,
procurement management and licensing activities necessary in the design,
manufacture, installation, construction, maintenance and operation of the
Nuclear Steam Supply System. 
Instrumentation and Control (I&C) Engineering Services include the
design, analysis, configuration, testing, and installation of nuclear power
plant information, control, and protection systems.

 

“Mechanical
Equipment Parts Engineering Services” include the activities to develop and
maintain system/component information, manage replacement component
obsolescence issues, and conduct equipment qualification/re-qualification,
including seismic, environmental and electromagnetic capability testing.   Shop services include Westinghouse low
voltage breaker model DB, DS, and medium voltage model DHP refurbishment and
new replacement breakers.

 

“Nuclear Field Services” consist of those
field services requiring a basic knowledge of nuclear plant hardware and
systems processes along with knowledge and application of field service
techniques, principles and practices. 
Field services include services generally performed at the Site, and
those related headquarters activities provided before, during and after the
performance of the applicable field services. 
These services are typically involved with the maintenance, inspection,
repair, modification and/or installation of plant systems and components,
including I&C components.

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

Page 4 of 5

 

	
  Execution
  Version

  	
  Confidential Trade Secret Information—Subject to
  Restricted Procedures

  

 

G.2 STONE & WEBSTER TIME
AND MATERIALS AND TARGET PRICE RATES AND CHARGES

 

Stone & Webster
Time and Materials and Target Price Work shall be compensated and billed as
follows:

 

	
  ID

  	
   

  	
  BILLING BASIS (Note 2)

  
	
  L1

  	
  [**]

  	
  [**]

  
	
  L2

  	
  [**]

  	
  [**]

  
	
  E

  	
  [**]

  	
  [**]

  
	
  G

  	
  [**]

  	
  [**]

  
	
  P

  	
  [**]

  	
  [**]

  
	
  T

  	
  [**]

  	
  [**]

  

 

	
  *

  	
  [**]

  
	
  **

  	
  [**]

  
	
  ***

  	
  [**]

  

 

Notes:

	
  (1)

  	
  [**]

  
	
  (2)

  	
  [**]

  
	
  (3)

  	
  [**]

  
	
  (4)

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

Page 5 of 5

 

	
  Execution
  Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

EXHIBIT H

PRICING

 

Capitalized
terms used herein and not otherwise defined herein have the meanings assigned
to such terms in the Agreement to which this Exhibit H is appended.

 

H.1          Introduction

 

The
Contract Price and its component parts are provided in Attachment 1 of this
Exhibit.  [**]  The Contract Price shall be subject to price
adjustment for escalation and other cost conditions per Exhibit J and
Changes per Article 9 of the Agreement.

 

This
Exhibit also describes the process and methodology by which the Contract
Price will be refined and modified during the term of the Agreement.

 

H.2          Elements of the Contract Price

 

[**]

 

H.2.1      [**]

 

[**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

1 of 14

 

	
  Execution
  Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

Table H.2.1

 

	
  WORK
  SCOPES

  	
  [**]

  
	
  [**]

  	
   

  
	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  
	
  [**]

  	
  [**]

  
	
  [**]

  
	
  [**]

  
	
  [**]

  
	
  [**]

  	
  [**]

  

 

[**]

 

H.2.2      [**]

 

[**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

2 of 14

 

	
  Execution
  Version

  	
  Confidential Trade Secret Information—Subject to Restricted Procedures

  

 

[**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

3 of 14

 

	
  Execution
  Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

[**]

 

Cases 1, 2 and 3

 

[**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

4 of 14

 

	
  Execution
  Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

[**]

 

Case 4

 

[**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

5 of 14

 

	
  Execution
  Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

[**]

 

Case 5

 

[**]

 

H.2.3      [**]

 

[**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

6 of 14

 

	
  Execution
  Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

[**]

 

H.2.4      [**]

 

[**]

 

H.2.5      [**]

 

[**]

 

H.2.6      [**]

 

[**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

7 of 14

 

	
  Execution
  Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

[**]

 

H.2.7      [**]

 

[**]

 

H.2.8      Calculation of the Pricing

 

	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
   

  
	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

8 of 14

 

	
  Execution
  Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

H.3          [**]

 

[**]

 

H.4          Guidelines for Contractor’s Support of Owner’s FERC and
SC PSC Cost Reporting Requirements

 

Contractor will provide
Owner with documentation to support Owner’s compliance with Federal Energy
Regulatory Commission and the South Carolina Public Service Commission cost
reporting requirements.  The detailed
process to provide this documentation will be included in the Project Execution
Plan using the following guidelines:

 

[**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

9 of 14

 

	
  Execution
  Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

[**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

10 of 14

 

	
  Execution
  Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

Attachment 1 to Exhibit H

Contract Price

 

1.                                       Contract Price. The Contract Price is
set forth below.  The Base Date which
will be used for price adjustment in accordance with Exhibit J — Price
Adjustment Provisions is [**].

 

[**]

 

The
Contract Price is [**]

 

The
Westinghouse Phase 1A work has a value of [**] that was paid under separate
agreement.  This amount is included in
the above Contract Price but is not included in any of the below tables or in Exhibit F-1
— Milestone Payment Schedule or in Exhibit F-2 — Payment Plan.

 

1.a.          [**]

 

	
   

  	
  Unit 2

  	
  Unit 3

  	
  Total

  
	
  Westinghouse portion

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Stone &Webster portion

  	
  [**]

  	
   

  	
  [**]

  

 

*[**]

**[**]

 

1.b.          [**]

 

	
   

  	
  Unit 2

  	
  Unit 3

  	
  Total

  
	
  Westinghouse portion

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Stone &Webster portion

  	
  [**]

  	
  [**]

  	
  [**]

  

 

1.c.          [**]

 

	
   

  	
  Unit 2

  	
  Unit 3

  	
  Total

  
	
  Westinghouse portion

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Stone &Webster portion

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in
this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

11 of 14

 

	
  Execution
  Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

1.d.          [**]

 

	
   

  	
  Unit 2

  	
  Unit 3

  	
  Total

  
	
  Westinghouse portion

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Stone &Webster portion

  	
  [**]

  	
  [**]

  	
  [**]

  

 

1.e.          [**]

 

	
   

  	
  Unit 2

  	
  Unit 3

  	
  Total

  
	
  Westinghouse portion

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Stone &Webster portion*

  	
  [**]

  	
  [**]

  	
  [**]

  

 

*[**]

 

1.f.           [**]

 

	
   

  	
  Unit 2

  	
  Unit 3

  	
  Contingency

  	
  Profit

  	
  Total

  
	
  Westinghouse portion

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Westinghouse portion

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  Stone &Webster portion

  	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Stone &Webster portion

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in
this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

12 of 14

 

	
  Execution
  Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

1.g.          [**]

 

	
   

  	
  Westinghouse

  	
  Stone & Webster

  
	
  Unit 2

  	
   

  	
   

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
   

  	
   

  	
   

  
	
  Unit 3

  	
   

  	
   

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

13 of 14

 

	
  Execution
  Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

Attachment 2 to Exhibit H

[**]

 

The following tables provide a
breakdown of the Westinghouse [**] shown in Exhibit H — Attachment 1
section 1.e above along with the associated estimate or allowance.

 

[**]

 

	
  Scope
  of Work

  	
  Westinghouse Scope

  Estimate

  	
  Stone & Webster

  Scope Estimate

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  

 

*   [**]

 

Owner Allowances

 

The
Stone & Webster Amount is included in Attachment 1, Table 1.e [**]

 

The
Westinghouse Amount is included in Attachment 1, Table 1.a [**]

 

	
  Description

  	
  Westinghouse Amount

  	
  Stone & Webster Amount

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  

 

*[**]

**[**]

 

[**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

14 of 14

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

EXHIBIT
I-1

Toshiba Parent Guaranty

 

[Form of
Parent Company Payment Guaranty]

 

GUARANTY OF TOSHIBA

 

This
Guaranty is made
by TOSHIBA CORPORATION (“Guarantor”), a corporation duly organized and existing
under the laws of Japan and the indirect parent of Westinghouse Electric
Company LLC (“Westinghouse”), in favor of South Carolina Electric &
Gas Company, for itself and as agent for the South Carolina Public Service Authority
(collectively, the “Counterparty”).

 

WHEREAS, Westinghouse and Stone &
Webster, Inc. (“Stone & Webster”, and collectively with
Westinghouse, the “Contractor”) and the Counterparty are parties to the
Engineering, Procurement and Construction Agreement between the Contractor and
the Counterparty, dated as of [                            ]
(the “Agreement”); and

 

WHEREAS, Guarantor, as indirect parent of
Westinghouse, shall receive substantial and direct benefits from the
transaction contemplated by the Agreement and has agreed to enter into this
Guaranty to provide assurance for 
Westinghouse’s payment obligations in connection with the Agreement and
to induce the Counterparty to enter into the Agreement; and

 

WHEREAS, the execution and delivery of this
Guaranty is a condition to the Counterparty’s performance of its obligations
under the terms of the Agreement;

 

NOW,
THEREFORE, in
consideration of the premises and other good and valuable consideration, the
adequacy, receipt and sufficiency of which are hereby acknowledged, Guarantor
hereby agrees as follows:

 

1.             Guarantor hereby unconditionally, irrevocably and
absolutely guarantees to the Counterparty and its respective successors and
permitted assigns, the prompt and complete payment, when due and owing, of the
payment obligations of Westinghouse under the terms of the Agreement (the “Guaranteed
Obligations”).  If Westinghouse fails to
pay the Guaranteed Obligations, then Guarantor shall promptly pay for such
obligation following written notice from the Counterparty and subject to the
terms and conditions provided for herein. 
EXCEPT TO THE EXTENT THE PAYMENT OF LIQUIDATED DAMAGES COULD OTHERWISE
BE DEEMED TO BE SUCH DAMAGES, IN NO EVENT SHALL GUARANTOR BE LIABLE, WHETHER
BASED ON CONTRACT (INCLUDING BREACH, WARRANTY, INDEMNITY, ETC.), TORT
(INCLUDING FAULT, NEGLIGENCE AND STRICT LIABILITY), OR OTHERWISE FOR ANY
CONSEQUENTIAL, INDIRECT, SPECIAL, PENAL, OR INCIDENTAL LOSS, DAMAGE OR INJURY.

 

2.             Subject to the Contractor’s liability limitation in the
Agreement and the Guarantor’s liability limitation in Section 1 of this
Guaranty, Guarantor agrees to pay on demand any and all out-of-pocket costs
including reasonable legal fees and expenses, and other expenses incurred by
the Counterparty in enforcing the Guaranteed Obligations under this Guaranty.

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

Page 1 of 6

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

3.             Upon payment of any of the Guaranteed Obligations,
Guarantor shall be subrogated to the rights of the Counterparty against
Westinghouse with respect to such Guaranteed Obligations and the Counterparty
agrees to take, at Guarantor’s expense, such steps as Guarantor may reasonably
request to implement such subrogation; provided, that Guarantor shall not be
entitled to enforce or to receive any payments arising out of, or based upon,
such right of subrogation until all Guaranteed Obligations then due and owing
shall have been paid in full.

 

4.             The Guaranteed Obligations of Guarantor hereunder are
several from Westinghouse or any other person, and are primary obligations
concerning which Guarantor is the principal obligor.  There are no conditions precedent to the
enforcement of this Guaranty, except as expressly contained herein.  Subject to paragraph 7 below, it shall not be necessary for the
Counterparty, in
order to enforce performance by Guarantor under this Guaranty, to show any proof of Westinghouse’s default, to exhaust its
remedies against Westinghouse, any other guarantor, or any other person liable
for the performance of Westinghouse’s obligations under the Agreement.

 

5.             This Guaranty shall remain in full force and effect or
shall be reinstated (as the case may be), if at any time any payment guaranteed
hereunder, in whole or in part, is annulled, set aside, invalidated, declared
to be fraudulent or preferential, rescinded or must otherwise be returned by
the Counterparty upon the bankruptcy, insolvency, dissolution, reorganization
or liquidation of Westinghouse, or upon or as a result of the appointment of a
receiver or conservator of, or trustee for Westinghouse or otherwise, all as
though such payment had not been made.

 

6.             The Counterparty may at any time and from time to time
without notice to or consent of Guarantor and without impairing or releasing
the Guaranteed Obligations of Guarantor hereunder:

 

(a)           agree with Westinghouse to make any
change in the terms of any obligation or liability of Westinghouse to the
Counterparty under the Agreement;

 

(b)           take or fail to take any action of
any kind in respect of any security for any obligation or liability of
Westinghouse to Counterparty;

 

(c)           exercise or refrain from exercising
any rights against Westinghouse or others; or

 

(d)           subordinate any obligation or
liability of Westinghouse to Counterparty including any security therefore.

 

Any additional suretyship
defenses are hereby waived by Guarantor. 
This Guaranty constitutes a Guaranty of payment and not merely of
collection.

 

7.             Notwithstanding any other provisions of this Guaranty
and without limiting Guarantor’s other defenses and rights hereunder: (a) Guarantor
reserves to itself all rights and defenses to which Westinghouse is or may be
entitled to arising under the Agreement (including, without limitation, any
right to cure under Section 22.2 of the Agreement), except for defenses
arising out of the bankruptcy, insolvency, dissolution or liquidation of
Westinghouse, and (b) the

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

Page 2 of 6

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

liability of Guarantor
under this Guaranty shall be subject to the limitations applicable to the
underlying obligations of Westinghouse under the Agreement.

 

8.             Guarantor hereby waives diligence; presentment; protest;
notice of protest, acceleration, and dishonor; filing of claims with a court in
the event of insolvency or bankruptcy of Westinghouse; all demands whatsoever,
except as noted in the first paragraph hereof; and any right to require a
proceeding first against Westinghouse or any other guarantor or surety for
either of them.

 

9.             Guarantor hereby certifies and warrants that this
Guaranty constitutes the valid obligation of Guarantor and complies with all
applicable laws.

 

10.           This Guaranty becomes effective on
the later of the date hereof or the date of the effectiveness of the
Agreement.  This Guaranty terminates on
the date of “Substantial Completion”, as such term is defined in the Agreement.

 

11.           Any notice, request, instruction,
correspondence or other document to be given hereunder by any party to another
(herein collectively called “Notice”) shall be in writing and delivered
personally or mailed by certified mail, postage prepaid and return receipt
requested, or by telecopier, as follows:

 

	
  To Counterparty:

  	
   

  	
  South Carolina
  Electric & Gas Company

  
	
   

  	
   

  	
  Attn: President

  
	
   

  	
   

  	
  Mail Code 190

  
	
   

  	
   

  	
  Columbia, SC 29218

  
	
   

  	
   

  	
  Telephone No.:
  803-217-8097

  
	
   

  	
   

  	
  Facsimile No.:
  803-217-9336

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  South Carolina Public
  Service Authority

  
	
   

  	
   

  	
  Attn: Chief Operating
  Officer (M602)

  
	
   

  	
   

  	
  One Riverwood Drive

  
	
   

  	
   

  	
  P.O. Box 2946101

  
	
   

  	
   

  	
  Moncks Corner, South
  Carolina 29461-6101

  
	
   

  	
   

  	
  Telephone No.: 843-761-4087

  
	
   

  	
   

  	
  Facsimile No.:
  843-761-7037

  
	
   

  	
   

  	
   

  
	
  With a copy to:

  	
   

  	
  South Carolina
  Electric & Gas Company

  
	
   

  	
   

  	
  Attn: General Counsel

  
	
   

  	
   

  	
  Mail Code 190

  
	
   

  	
   

  	
  Columbia, SC 29218

  
	
   

  	
   

  	
  Telephone No.:
  803-217-8634

  
	
   

  	
   

  	
  Facsimile No.:
  803-217-9336

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  South Carolina Public
  Service Authority

  
	
   

  	
   

  	
  Attn: General Counsel
  (M603)

  
	
   

  	
   

  	
  One Riverwood Drive

  
	
   

  	
   

  	
  P.O. Box 2946101

  
	
   

  	
   

  	
  Moncks Corner, South
  Carolina 29461-6101

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

Page 3 of 6

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

	
   

  	
   

  	
  Telephone No.:
  843-761-7007

  
	
   

  	
   

  	
  Facsimile No.:
  843-761-7037

  
	
   

  	
   

  	
   

  
	
  To Guarantor:

  	
   

  	
  Toshiba Corporation

  
	
   

  	
   

  	
  Attn: Vice President, WEC Coordination
  Division

  
	
   

  	
   

  	
  Power Systems Company

  
	
   

  	
   

  	
  1-1, Shibaura 1-chome, Minato-ku

  
	
   

  	
   

  	
  Tokyo 105-8001, Japan

  
	
   

  	
   

  	
  Telephone No: +81-3-3457-3752

  
	
   

  	
   

  	
  Facsimile No: +81-3-

  

 

Notice shall be effective
on the Business Day it is delivered except that any Notice that is not
delivered prior to the end of normal business hours shall be effective as of
the Business Day following the day it is delivered.  Any party may change any address to which
Notice is to be given to it by giving notice as provided above of such change
of address.

 

12.           Counterparty may, upon notice to
Guarantor, assign its rights hereunder without the consent of Guarantor.  Guarantor may assign its rights hereunder
with the prior written consent of Counterparty, which consent shall not be
unreasonably withheld.  Subject to the
foregoing, this Guaranty shall be binding upon and inure to the benefit of the
parties hereto and their respective successors, permitted assigns and legal
representatives.

 

13.           Guarantor represents and warrants
that:

 

(a)           it is a corporation duly organized,
validly existing and in good standing under the laws of Japan and has the
corporate or equivalent power and authority to execute, deliver and perform the
Guaranteed Obligations under this Guaranty;

 

(b)           no authorization, approval, consent
or order of, or registration or filing with, any court or governmental
authority having jurisdiction over Guarantor is required on the part of Guarantor
for the execution, delivery and performance of this Guaranty which has not been
obtained or duly submitted, as applicable;

 

(c)           this Guaranty, when executed and
delivered, shall constitute a valid and legally binding agreement of Guarantor,
except as the enforceability of this Guaranty may be limited by the effect of
any applicable bankruptcy, insolvency, reorganization, moratorium or similar
laws affecting creditor’s rights generally and by general principles of equity;
and

 

(d)           the execution, delivery and
performance by Guarantor of this Guaranty does not and shall not contravene any
law applicable to Guarantor or its organizational documents and does not and
shall not conflict with or result in the breach of or default under any
indenture, mortgage, agreement, instrument, judgment, decree, order or ruling
to which Guarantor is a party or by which any of its properties are bound.

 

14.           The validity, construction, and
performance of this Guaranty shall be governed by and interpreted in accordance
with the laws of the State of New York, without giving effect to

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

Page 4 of 6

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

the principles thereof
relating to conflicts of laws except Section 5-1401 of the New York
General Obligations Law.

 

15.           Guarantor and the Counterparty agree
to the exclusive jurisdiction of the United States District Court for the
Southern District of New York or, if such court does not have jurisdiction of
the matter, the courts of the State of New York located in the City and County
of New York, for any legal proceedings that may be brought by Guarantor or the
Counterparty arising out of or in connection with this Guaranty or for recognition or enforcement of
any judgment.  By execution and delivery
of this Guaranty, each of Guarantor and the Counterparty accepts, generally and
unconditionally, the jurisdiction of the aforesaid court for legal proceedings
arising out of or in connection with this Guaranty.  Each of 
Guarantor and the Counterparty hereby waives any right to stay or
dismiss any action or proceeding under or in connection with this Guaranty
brought before the foregoing court on the basis of forum non-conveniens or
improper venue.

 

16.           EACH OF GUARANTOR AND THE
COUNTERPARTY HEREBY IRREVOCABLY WAIVES ALL RIGHT TO TRIAL BY JURY IN ANY
ACTION, PROCEEDING OR COUNTERCLAIM (WHETHER BASED ON CONTRACT, TORT OR
OTHERWISE) ARISING OUT OF OR RELATING TO THIS GUARANTY.

 

17.           This Guaranty embodies the entire
agreement and understanding between Guarantor and Counterparty and supersedes
all prior and contemporaneous agreements and understandings relating to the
subject matter hereof.

 

18.           The provisions of this Guaranty are
intended for the sole benefit of Guarantor and Counterparty, and Guarantor and
Counterparty do not intend to create any third party beneficiaries or otherwise
create privity of contract with any other person.

 

19.           This Guaranty may be executed in two
or more counterparts, each of which shall be deemed an original, but all of
which together shall constitute one and the same instrument.

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

Page 5 of 6

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

IN WITNESS WHEREOF,
Guarantor has caused this Guaranty to be executed in its corporate name by its
duly authorized representative.

 

	
   

  	
  TOSHIBA
  CORPORATION

  
	
   

  	
   

  
	
   

  	
  By:

  	
   

  
	
   

  	
   

  	
   

  
	
   

  	
  Name: 

  	
   

  
	
   

  	
   

  	
   

  
	
   

  	
  Title:

  	
   

  
	
   

  	
   

  	
   

  
	
   

  	
  Date:

  	
   

  
	
   

  	
   

  	
   

  

 

Acknowledged and Agreed
by Counterparty as of this        day of                       ,
2008, by:

 

	
   

  	
   

  
	
  Name:

  	
   

  
	
  Title:

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

Page 6 of 6

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT I-2

 

Shaw Parent Guaranty

 

[Form of Parent Company Payment Guaranty]

 

GUARANTY OF THE SHAW
GROUP INC.

 

This Guaranty is made by The Shaw Group
Inc. (“Guarantor”), a corporation duly organized and existing under the laws of
Louisiana and the parent of Stone & Webster, Inc. (“Stone &
Webster”), in favor of South Carolina Electric & Gas Company, for
itself and as agent for the South Carolina Public Service Authority
(collectively, the “Counterparty”).

 

WHEREAS, Stone & Webster and Westinghouse
Electric Company LLC (“Westinghouse”, and collectively with Stone &
Webster, the “Contractor”) and the Counterparty are parties to the Engineering,
Procurement and Construction Agreement between the Contractor and the
Counterparty, dated as of [                      ]
(the “Agreement”); and

 

WHEREAS, Guarantor, as parent of Stone &
Webster, shall receive substantial and direct benefits from the transaction
contemplated by the Agreement and has agreed to enter into this Guaranty to
provide assurance for Stone & Webster’s payment obligations in
connection with the Agreement and to induce the Counterparty to enter into the
Agreement; and

 

WHEREAS, the execution and delivery of this Guaranty
is a condition to the Counterparty’s performance of its obligations under the
terms of the Agreement;

 

NOW, THEREFORE, in consideration of the
premises and other good and valuable consideration, the adequacy, receipt and
sufficiency of which are hereby acknowledged, Guarantor hereby agrees as
follows:

 

1.             Guarantor hereby unconditionally,
irrevocably and absolutely guarantees to the Counterparty and its respective
successors and permitted assigns, the prompt and complete payment, when due and
owing, of the payment obligations of Stone & Webster under the terms
of the Agreement (the “Guaranteed Obligations”); [**].  If Stone & Webster fails to pay the
Guaranteed Obligations, then Guarantor shall promptly pay for such obligation
following written notice from the Counterparty and subject to the terms and
conditions provided for herein.  EXCEPT
TO THE EXTENT THE PAYMENT OF LIQUIDATED DAMAGES COULD OTHERWISE BE DEEMED TO BE
SUCH DAMAGES, IN NO EVENT SHALL GUARANTOR BE LIABLE, WHETHER BASED ON CONTRACT
(INCLUDING BREACH, WARRANTY, INDEMNITY, ETC.), TORT (INCLUDING FAULT,
NEGLIGENCE AND STRICT LIABILITY), OR OTHERWISE FOR ANY CONSEQUENTIAL, INDIRECT,
SPECIAL, PENAL, OR INCIDENTAL LOSS, DAMAGE OR INJURY.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
1 of 6

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

2.             Subject to the Contractor’s
liability limitation in the Agreement and the Guarantor’s liability limitation
in Section 1 of this Guaranty, Guarantor agrees to pay on demand any and
all out-of-pocket costs including reasonable legal fees and expenses, and other
expenses incurred by the Counterparty in enforcing the Guaranteed Obligations
under this Guaranty.

 

3.             Upon payment of any of the
Guaranteed Obligations, Guarantor shall be subrogated to the rights of the
Counterparty against Stone & Webster with respect to such Guaranteed
Obligations and the Counterparty agrees to take, at Guarantor’s expense, such
steps as Guarantor may reasonably request to implement such subrogation;
provided, that Guarantor shall not be entitled to enforce or to receive any
payments arising out of, or based upon, such right of subrogation until all
Guaranteed Obligations then due and owing shall have been paid in full.

 

4.             The Guaranteed Obligations of
Guarantor hereunder are several from Stone & Webster or any other
person, and are primary obligations concerning which Guarantor is the principal
obligor.  There are no conditions
precedent to the enforcement of this Guaranty, except as expressly contained
herein.  Subject to paragraph 7 below, it
shall not be necessary for the Counterparty, in order to enforce performance by
Guarantor under this Guaranty, to show any proof of Stone & Webster’s
default, to exhaust its remedies against Stone & Webster, any other
guarantor, or any other person liable for the performance of Stone &
Webster’s obligations under the Agreement.

 

5.             This Guaranty shall remain in full
force and effect or shall be reinstated (as the case may be), if at any time
any payment guaranteed hereunder, in whole or in part, is annulled, set aside,
invalidated, declared to be fraudulent or preferential, rescinded or must
otherwise be returned by the Counterparty upon the bankruptcy, insolvency,
dissolution, reorganization or liquidation of Stone & Webster or upon
or as a result of the appointment of a receiver or conservator of, or trustee
for Stone & Webster or otherwise, all as though such payment had not
been made.

 

6.             The Counterparty may at any time
and from time to time without notice to or consent of Guarantor and without
impairing or releasing the Guaranteed Obligations of Guarantor hereunder:

 

(a)           agree with Stone & Webster
to make any change in the terms of any obligation or liability of Stone &
Webster to the Counterparty under the Agreement;

 

(b)           take or fail to take any action of
any kind in respect of any security for any obligation or liability of Stone &
Webster to the Counterparty;

 

(c)           exercise or refrain from exercising
any rights against Stone & Webster or others; or

 

(d)           subordinate any obligation or
liability of Stone & Webster to the Counterparty including any
security therefor.

 

Any
additional suretyship defenses are hereby waived by Guarantor.  This Guaranty constitutes a guaranty of
payment and not merely of collection.

 

“[**]” in this Exhibit 10.01 indicates material
that has been omitted pursuant to a request for confidential treatment and
filed separately with the Securities and Exchange Commission.

 

Page
2 of 6

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

7.             Notwithstanding any other
provisions of this Guaranty and without limiting Guarantor’s other defenses and
rights hereunder: (a) Guarantor reserves to itself all rights and defenses
to which Stone & Webster is or may be entitled to arising under the
Agreement (including, without limitation, any right to cure under Section 22.2
of the Agreement), except for defenses arising out of the bankruptcy,
insolvency, dissolution or liquidation of Stone & Webster, and (b) the
liability of Guarantor under this Guaranty shall be subject to the limitations
applicable to the underlying obligations of Stone & Webster under the
Agreement.

 

8.             Guarantor hereby waives diligence; presentment; protest;
notice of protest, acceleration, and dishonor; filing of claims with a court in
the event of insolvency or bankruptcy of Stone & Webster; all demands
whatsoever, except as noted in the first paragraph hereof; and any right to
require a proceeding first against Stone & Webster or any other guarantor
or surety for either of them.

 

9.             Guarantor hereby certifies and
warrants that this Guaranty constitutes the valid obligation of Guarantor and
complies with all applicable laws.

 

10.           This Guaranty becomes effective on
the later of the date hereof or the date of the effectiveness of the
Agreement.  This Guaranty terminates on
the date of “Substantial Completion”, as such term is defined in the Agreement.

 

11.           Any notice, request, instruction, correspondence or other
document to be given hereunder by any party to another (herein collectively
called “Notice”) shall be in writing and delivered personally or mailed by
certified mail, postage prepaid and return receipt requested, or by telecopier,
as follows:

 

	
  To
  Counterparty:

  	
   

  	
  South
  Carolina Electric & Gas Company

  
	
   

  	
   

  	
  Attn:
  President

  
	
   

  	
   

  	
  Mail
  Code 190

  
	
   

  	
   

  	
  Columbia,
  SC 29218

  
	
   

  	
   

  	
  Telephone
  No.: 803-217-8097

  
	
   

  	
   

  	
  Facsimile
  No.: 803-217-9336

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  South
  Carolina Public Service Authority

  
	
   

  	
   

  	
  Attn:
  Chief Operating Officer (M602)

  
	
   

  	
   

  	
  One
  Riverwood Drive

  
	
   

  	
   

  	
  P.O. Box
  2946101

  
	
   

  	
   

  	
  Moncks
  Corner, South Carolina 29461-6101

  
	
   

  	
   

  	
  Telephone
  No.: 843-761-4087

  
	
   

  	
   

  	
  Facsimile
  No.: 843-761-7037

  
	
   

  	
   

  	
   

  
	
  With a copy to:

  	
   

  	
  South Carolina
  Electric & Gas Company

  
	
   

  	
   

  	
  Attn: General Counsel

  
	
   

  	
   

  	
  Mail Code 190

  
	
   

  	
   

  	
  Columbia, SC 29218

  
	
   

  	
   

  	
  Telephone No.: 803-217-8634

  
	
   

  	
   

  	
  Facsimile No.:
  803-217-9336

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
3 of 6

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
   

  	
   

  	
  South
  Carolina Public Service Authority

  
	
   

  	
   

  	
  Attn:
  General Counsel (M603)

  
	
   

  	
   

  	
  One
  Riverwood Drive

  
	
   

  	
   

  	
  P.O. Box
  2946101

  
	
   

  	
   

  	
  Moncks
  Corner, South Carolina 29461-6101

  
	
   

  	
   

  	
  Telephone
  No.: 843-761-7007

  
	
   

  	
   

  	
  Facsimile
  No.: 843-761-7037

  
	
   

  	
   

  	
   

  
	
  To
  Guarantor:

  	
   

  	
  The Shaw Group
  Inc.

  
	
   

  	
   

  	
  4171 Essen Lane

  
	
   

  	
   

  	
  Baton Rouge, LA
  70809

  
	
   

  	
   

  	
  Attention: General
  Counsel

  

 

Notice shall be effective on
the Business Day it is delivered except that any Notice that is not delivered
prior to the end of normal business hours shall be effective as of the Business
Day following the day it is delivered. 
Any party may change any address to which Notice is to be given to it by
giving notice as provided above of such change of address.

 

12.           The Counterparty may, upon notice to
Guarantor, assign its rights hereunder without the consent of Guarantor.  Guarantor may assign its rights hereunder
with the prior written consent of the Counterparty, which consent shall not be
unreasonably withheld.  Subject to the
foregoing, this Guaranty shall be binding upon and inure to the benefit of the
parties hereto and their respective successors, permitted assigns and legal
representatives.

 

13.           Guarantor represents and warrants
that:

 

(a)           it is a corporation duly organized,
validly existing and in good standing under the laws of Louisiana and has the
corporate or equivalent power and authority to execute, deliver and perform the
Guaranteed Obligations under this Guaranty;

 

(b)           no authorization, approval, consent
or order of, or registration or filing with, any court or governmental
authority having jurisdiction over Guarantor is required on the part of
Guarantor for the execution, delivery and performance of this Guaranty which
has not been obtained or duly submitted, as applicable;

 

(c)           this Guaranty, when executed and
delivered, shall constitute a valid and legally binding agreement of Guarantor,
except as the enforceability of this Guaranty may be limited by the effect of
any applicable bankruptcy, insolvency, reorganization, moratorium or similar
laws affecting creditor’s rights generally and by general principles of equity;
and

 

(d)           the execution, delivery and
performance by Guarantor of this Guaranty does not and shall not contravene any
law applicable to Guarantor or its organizational documents and does not and
shall not conflict with or result in the breach of or default under any
indenture, mortgage, agreement, instrument, judgment, decree, order or ruling
to which Guarantor is a party or by which any of its properties are bound.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
4 of 6

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

14.           The validity, construction, and
performance of this Guaranty shall be governed by and interpreted in accordance
with the laws of the State of New York, without giving effect to the principles
thereof relating to conflicts of laws except Section 5-1401 of the New
York General Obligations Law.

 

15.           Guarantor and the Counterparty agree to the exclusive
jurisdiction of the United States District Court for the Southern District of
New York or, if such court does not have jurisdiction of the matter, the courts
of the State of New York located in the City and County of New York, for any legal
proceedings that may be brought by Guarantor or the Counterparty arising out of
or in connection with this Guaranty  or
for recognition or enforcement of any judgment. 
By execution and delivery of this Guaranty, each of Guarantor and the
Counterparty accepts, generally and unconditionally, the jurisdiction of the
aforesaid court for legal proceedings arising out of or in connection with this
Guaranty.  Each of Guarantor and the
Counterparty hereby waives any right to stay or dismiss any action or proceeding
under or in connection with this Guaranty brought before the foregoing court on
the basis of forum non-conveniens or improper venue.

 

16.           EACH OF GUARANTOR AND THE COUNTERPARTY HEREBY IRREVOCABLY
WAIVES ALL RIGHT TO TRIAL BY JURY IN ANY ACTION, PROCEEDING OR COUNTERCLAIM
(WHETHER BASED ON CONTRACT, TORT OR OTHERWISE) ARISING OUT OF OR RELATING TO
THIS GUARANTY.

 

17.           This Guaranty embodies the entire agreement and
understanding between Guarantor and the Counterparty and supersedes all prior
and contemporaneous agreements and understandings relating to the subject
matter hereof.

 

18.           The provisions of this Guaranty are
intended for the sole benefit of Guarantor and the Counterparty, and Guarantor
and the Counterparty do not intend to create any third party beneficiaries or
otherwise create privity of contract with any other person.

 

19.           This Guaranty may be executed in two
or more counterparts, each of which shall be deemed an original, but all of
which together shall constitute one and the same instrument.

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
5 of 6

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

IN
WITNESS WHEREOF, Guarantor has caused this Guaranty to be executed in its
corporate name by its duly authorized representative.

 

	
   

  	
  THE SHAW GROUP INC.

  
	
   

  	
   

  
	
   

  	
  By:

  	
   

  
	
   

  	
   

  	
   

  
	
   

  	
  Name: 

  	
   

  
	
   

  	
   

  	
   

  
	
   

  	
  Title:

  	
   

  
	
   

  	
   

  	
   

  
	
   

  	
  Date:

  	
   

  
	
   

  	
   

  	
   

  

 

Acknowledged
and Agreed by Counterparty as of this        day
of                       ,
2008, by:

 

	
   

  	
   

  
	
  Name:
  

  	
   

  
	
  Title:

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
6 of 6

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

Exhibit J

Price Adjustment Provisions

 

J.1          Introduction

 

Exhibit H — Pricing describes the
elements of the Contract Price and provides the breakdown of the Contract Price
into [**].  [**]  For the purpose of applying the provisions of
this exhibit, the Contract Price has a “Base Date” (BD) of [**].  [**]  [**] will be escalated and adjusted in
accordance with the adjustment provisions provided herein.

 

J.2          Price Adjustment Overview

 

The application of the
adjustment provisions for each of the price categories: [**]

 

[**]

 

Table
J-1 provides a list of project elements and shows the type of adjustment that
will be applied to the cost elements for each Consortium Member

 

J.2.1       [**]

 

[**]

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 1 of 16

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

J.2.2       [**]

 

[**]

 

J.2.3       [**]

 

[**]

 

J.2.4       [**]

 

[**]

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 2 of 16

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

[**]

 

J.3          Pricing
Categories

 

J.3.1       [**]

 

[**]

 

J.3.2       [**]

 

[**]

 

J.3.3       [**]

 

[**]

 

J.4          Adjustment Provisions

 

J.4.1       [**]

 

[**]

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 3 of 16

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

[**]

 

	
  Adjustment Method

  	
   

  	
  Adjustment Process

  
	
   

  	
   

  	
   

  
	
  [**]

  	
   

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 4 of 16

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

[**]

 

Price Adjustment Example

 

Example 1 — [**]

 

[**]

 

	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

[**]

 

	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 5 of 16

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

Example 2

 

[**]

 

J.4.2       [**]

 

[**]

 

J.4.3       [**]

 

[**]

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 6 of 16

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

[**]

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 7 of 16

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

[**]

 

	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
  [**]

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
  [**]

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
  [**]

  	
  [**]

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
  [**]

  	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  [**]

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  [**]

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  [**]

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  [**]

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  [**]

  	
  [**]

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page
8 of 16

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

[**]

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page
9 of 16

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

TABLE J-1

 

Cost Elements Subject to Adjustment

 

	
  Adjustment Category

  	
  Cost Make-up

  	
  WEC

  	
  S&W

  
	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
  [**]

  	
  [**]

  	
  [**]

  	
   

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

[**]

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 10 of 16

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted Procedures

  

 

TABLE J-2

 

Price
Adjustment Indices

 

	
  Index
  ID

  	
  Index
  Description

  
	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 11 of 16

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

TABLE J-3

 

[**]

November 2007 Base Date

 

	
   

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 12 of 16

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

	
   

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 13 of 16

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

	
   

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 14 of 16

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

	
   

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 15 of 16

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

Table J-4

 

	
   

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

[**]

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

Page 16 of 16

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

EXHIBIT K

Costs

 

Capitalized terms used herein and not otherwise
defined herein have the meanings assigned to such terms in the Agreement to
which this Exhibit K is appended.

 

Cost categories shall include those categories of
charges that can be directly traced to producing specific goods or services for
or in connection with the Work as well as the general overhead costs of
Contractor. [**]  Any and all other costs or charges identified
that are not included in Table K-1, that are incurred for the benefit of the
Work may be added subject to Owner’s approval.

 

[**] A specific charge will only be accounted for
in one cost category and will not be double accounted.

 

The
following tables list the specific categories of Costs.

 

“HQ”
is Headquarters related to personnel assigned to the home offices.

 

“Site
Assigned” is related to personnel whose assignment has been changed to the
site.

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 1 of 8

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

	
  Table
  K-1: Direct / Billable Charges

  
	
  Item

  No.

  	
  Cost
  Categories

  	
  Recoverable by Direct Charges for
  Time and

  Expenses Related to the Work

  (Yes/No)

  
	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  1.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  A

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  B

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  C

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  D

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  E

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  F

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  G

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  H

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  I

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  J

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  K

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  L

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  M

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

[**]

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 2 of 8

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

	
  Table
  K-1: Direct / Billable Charges

  
	
  Item

  No.

  	
  Cost
  Categories

  	
  Recoverable by Direct Charges for
  Time and

  Expenses Related to the Work

  (Yes/No)

  
	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  N

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  O

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  P

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  Q

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  R

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  S

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  T

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  U

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  V

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  W

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  2.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  3.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 3 of 8

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted Procedures

  

 

	
  Table
  K-1: Direct / Billable Charges

  
	
  Item

  No.

  	
  Cost
  Categories

  	
  Recoverable by Direct Charges for
  Time and

  Expenses Related to the Work

  (Yes/No)

  
	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  4.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  5.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  6.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  7.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

[**]

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 4 of 8

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

	
  Table
  K-1: Direct / Billable Charges

  
	
  Item

  No.

  	
  Cost
  Categories

  	
  Recoverable by Direct Charges for
  Time and

  Expenses Related to the Work

  (Yes/No)

  
	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  8.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  9.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  10.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  11.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  12.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  13.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

[**]

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 5 of 8

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

	
  Table
  K-1: Direct / Billable Charges

  
	
  Item

  No.

  	
  Cost
  Categories

  	
  Recoverable by Direct Charges for
  Time and

  Expenses Related to the Work

  (Yes/No)

  
	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  14.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  15.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  16.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  17.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  18.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 6 of 8

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

	
  Table K-2: SGA, G&A and
  Multiplier Items

  
	
  Item

  No.

  	
  Cost
  Categories

  	
  Charges
  for Time and Expenses Related to

  the Work Recoverable by Inclusion in

  Multipliers or SGA or G&A

  (Yes/No)

  
	
   

  	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  1.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  2.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  3.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  4.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  5.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  6.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  7.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  8.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  9.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  10.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  11.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  12.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  13.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  14.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 7 of 8

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject to Restricted
  Procedures

  

 

	
  Table K-2: SGA, G&A and
  Multiplier Items

  
	
  Item

  No.

  	
  Cost
  Categories

  	
  Charges
  for Time and Expenses Related to

  the Work Recoverable by Inclusion in

  Multipliers or SGA or G&A

  (Yes/No)

  
	
   

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  15.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  16.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  17.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  18.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  19.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  20.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  
	
  21.

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

“[**]” in this Exhibit 10.01 indicates material that has been
omitted pursuant to a request for confidential treatment and filed separately
with the Securities and Exchange Commission.

 

Page 8 of 8

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT
L

Net
Electrical Guarantee Conditions and Load List

 

Capitalized terms used
herein and not otherwise defined herein have the meanings assigned to such
terms in the Agreement to which this Exhibit L is appended.

 

[**] The Net Unit
Electrical Output for the Unit shall be determined by the Net Unit Electrical
Output Test in accordance with the applicable requirements set forth in Section 11.5
of the Agreement.

 

The purpose of this Exhibit is
to define the Net Unit Electric Output value for the Net Unit Electric Output
Guarantee and provide the House Loads for the Unit when defining the Net Unit
Electric Output Guarantee.  The House
Loads list with individual load operation assumptions (on/off) is presented in
Attachment A to this Exhibit.  (House
Loads are those which receive power from the Unit Auxiliary Transformers; that
is, supplied from the low voltage side of the Main Step-Up Transformers.)

 

[**]

 

The
Net Unit Electric Output of the Unit is:

 

	
  Plant Condition

  	
  Generator
  Output

  (kW)

  	
  House
  Loads (kW)

  [**]

  	
  Net
  Unit Electrical

  Output Guarantee (kW)

  [**]

  
	
  [**]

  	
  [**]

  	
  [**]

  	
  [**]

  

 

The
Net Unit Electrical Output Guarantee is based upon the following conditions:

 

·  [**]

·  [**]

·  [**]

·  [**]

·  [**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
1 of 20

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

·  [**]

·  [**]

·  [**]

·  [**]

 

[**]

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
2 of 20

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Attachment A

 

HOUSE LOADS

EQUIPMENT ON/OFF LIST

 

	
  Tag No.

  	
   

  	
  Component Description

  	
   

  	
  On/Off

  	
   

  	
  Load Note

  	
   

  
	
  2037-AD-D01

  	
   

  	
  ROLL-UP DOOR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  4033-MS-01

  	
   

  	
  HMS DECON SYSTEM (PORTABLE UNITS)

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  4033-MZ-01

  	
   

  	
  HMS DRILL PRESS

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  4033-MZ-02

  	
   

  	
  HMS BAND SAW

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  4033-MZ-03

  	
   

  	
  HMS POWER HACKSAW

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  4033-MZ-04

  	
   

  	
  HMS UNIVERSAL GRINDER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  4033-MZ-05

  	
   

  	
  HMS LATHE

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  4033-MZ-06

  	
   

  	
  HMS MILLING MACHINE

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ASS-EH-01

  	
   

  	
  AUXILIARY BOILER FUEL OIL ELECTRIC HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ASS-MP-01A

  	
   

  	
  AUXILIARY BOILER MAKEUP PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ASS-MP-01B

  	
   

  	
  AUXILIARY BOILER MAKEUP PUMP B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ASS-MP-04A

  	
   

  	
  AUXILIARY BOILER FEED PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ASS-MP-04B

  	
   

  	
  AUXILIARY BOILER FEED PUMP B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  BDS-MP-01

  	
   

  	
  STEAM GENERATOR RECIRCULATION AND DRAIN PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  BDS-MP-02A

  	
   

  	
  EDI BRINE PUMP A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  BDS-MP-02B

  	
   

  	
  EDI BRINE PUMP B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CAS-MS-01A

  	
   

  	
  INSTRUMENT AIR COMPRESSOR PACKAGE A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CAS-MS-01B`

  	
   

  	
  INSTRUMENT AIR COMPRESSOR PACKAGE B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CAS-MS-03A

  	
   

  	
  SERVICE AIR COMPRESSOR PACKAGE A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CAS-MS-03B

  	
   

  	
  SERVICE AIR COMPRESSOR PACKAGE B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CAS-MS-05

  	
   

  	
  HIGH PRESSURE AIR COMPRESSOR AND FILTER PACKAGE

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CCS-EH-01A

  	
   

  	
  CCS PUMP HEATER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CCS-EH-01B

  	
   

  	
  CCS PUMP HEATER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CCS-MP-01A

  	
   

  	
  COMPONENT COOLING WATER PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CCS-MP-01B

  	
   

  	
  COMPONENT COOLING WATER PUMP B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CCS-PL-V225

  	
   

  	
  Letdown HX Cooling Flow Inlet Isolation

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CCS-PL-V256A

  	
   

  	
  RCP 1A Cooling Water Outlet Isolation

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CCS-PL-V256B

  	
   

  	
  RCP 1B Cooling Water Outlet Isolation

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CCS-PL-V256C

  	
   

  	
  RCP 2A Cooling Water Outlet Isolation

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CCS-PL-V256D

  	
   

  	
  RCP 2B Cooling Water Outlet Isolation

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CDS-EH-01A

  	
   

  	
  CONDENSATE PUMP A MOTOR HTR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CDS-EH-01B

  	
   

  	
  CONDENSATE PUMP B MOTOR HTR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CDS-EH-01C

  	
   

  	
  CONDENSATE PUMP C MOTOR HTR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CDS-MP-01A

  	
   

  	
  CONDENSATE PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CDS-MP-01B

  	
   

  	
  CONDENSATE PUMP B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CDS-MP-01C

  	
   

  	
  CONDENSATE PUMP C

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
3 of 20

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Attachment A

 

HOUSE LOADS

EQUIPMENT ON/OFF LIST

 

	
  Tag No.

  	
   

  	
  Component Description

  	
   

  	
  On/Off

  	
   

  	
  Load Note

  	
   

  
	
  CDS-PL-V012

  	
   

  	
  VALVE CDS-PL-V012

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CDS-PL-V013

  	
   

  	
  VALVE CDS-PL-V013

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CDS-PL-V014

  	
   

  	
  F.W. HEATERS 1&2 BYPASS MOV

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CES-EP-01A

  	
   

  	
  CONDENSOR TUBE CLEANING PANEL A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CES-EP-01B

  	
   

  	
  CONDENSOR TUBE CLEANING PANEL B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-01

  	
   

  	
  OXYGEN SCAVENGING PUMP 1

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-02

  	
   

  	
  OXYGEN SCAVENGING PUMP 2

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-03

  	
   

  	
  PH CONTROL FEED PUMP 1

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-04

  	
   

  	
  PH CONTROL FEED PUMP 2

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-05

  	
   

  	
  ASS OXYGEN SCAVAGING PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-06

  	
   

  	
  ASS pH CONTROL FEED PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-07

  	
   

  	
  ASS BATCH CHEMICAL FEED PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-08A

  	
   

  	
  SWS DISPERSANT CHEMICAL FEED PUMP A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-08B

  	
   

  	
  SWS DISPERSANT CHEMICAL FEED PUMP B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-09A

  	
   

  	
  CWS DISPERSANT CHEMICAL FEED PUMP A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-09B

  	
   

  	
  CWS DISPERSANT CHEMICAL FEED PUMP B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-10

  	
   

  	
  DTS SCALE INHIBITOR CHEMICAL FEED PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-11

  	
   

  	
  CWS & SWS ALGAECIDE CHEMICAL FEED PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-12A

  	
   

  	
  SWS BIOCIDE CHEMICAL FEED PUMP A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-12B

  	
   

  	
  SWS BIOCIDE CHEMICAL FEED PUMP B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-13A

  	
   

  	
  CWS BIOCIDE CHEMICAL FEED PUMP A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-13B

  	
   

  	
  CWS BIOCIDE CHEMICAL FEED PUMP B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-14

  	
   

  	
  PWS BIOCIDE CHEMICAL FEED PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-15A

  	
   

  	
  SWS pH CONTROL CHEMICAL FEED PUMP A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-15B

  	
   

  	
  SWS pH CONTROL CHEMICAL FEED PUMP B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-16A

  	
   

  	
  CWS pH CONTROL CHEMICAL FEED PUMP A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-16B

  	
   

  	
  CWS pH CONTROL CHEMICAL FEED PUMP B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CFS-MP-17

  	
   

  	
  DTS pH CONTROL CHEMICAL FEED PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CMS-MK-01A

  	
   

  	
  VACUUM PUMP A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CMS-MK-01B

  	
   

  	
  VACUUM PUMP B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CMS-MK-01C

  	
   

  	
  VACUUM PUMP C

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CMS-MK-01D

  	
   

  	
  VACUUM PUMP D

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CMS-MP-01A

  	
   

  	
  SEAL WATER PUMP A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CMS-MP-01B

  	
   

  	
  SEAL WATER PUMP B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CMS-MP-01C

  	
   

  	
  SEAL WATER PUMP C

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CPS-PL-V001

  	
   

  	
  CPS BYPASS VALVE

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CPS-PL-V002

  	
   

  	
  POLISHER VESSEL UPSTREAM ISOLATION VALVE

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CPS-PL-V003

  	
   

  	
  POLISHER VESSEL DOWNSTREAM ISOLATION VALVE

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CVS-EH-01-A

  	
   

  	
  BORIC ACID TANK IMMERSION HEATER ELEMENT A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
4 of 20

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Attachment A

 

HOUSE LOADS

EQUIPMENT ON/OFF LIST

 

	
  Tag No.

  	
   

  	
  Component
  Description

  	
   

  	
  On/Off

  	
   

  	
  Load Note

  	
   

  
	
  CVS-EH-01-B

  	
   

  	
  BORIC ACID TANK IMMERSION HEATER ELEMENT B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CVS-EH-02

  	
   

  	
  BORIC ACID BATCHING TANK IMMERSION HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CVS-MP-01A

  	
   

  	
  MAKE-UP PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CVS-MP-01B

  	
   

  	
  MAKE-UP PUMP B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CVS-MY-Y01

  	
   

  	
  BORIC ACID BATCHING TANK MIXER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CWS-EH-01A

  	
   

  	
  Circulating Water Pump A Motor Heater

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CWS-EH-01B

  	
   

  	
  Circulating Water Pump B Motor Heater

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CWS-EH-01C

  	
   

  	
  Circulating Water Pump B Motor Heater

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CWS-MP-01A

  	
   

  	
  CIRCULATING WATER PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CWS-MP-01B

  	
   

  	
  CIRCULATING WATER PUMP B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CWS-MP-01C

  	
   

  	
  CIRCULATING WATER PUMP C

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CWS-PL-V001A

  	
   

  	
  C.W. PUMP A DISCHARGE MOV

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CWS-PL-V001B

  	
   

  	
  C.W. PUMP B DISCHARGE MOV

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CWS-PL-V002A

  	
   

  	
  L.P. CONDENSER A INLET MOV

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CWS-PL-V002B

  	
   

  	
  L.P.CONDENSER B INLET MOV

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CWS-PL-V003A

  	
   

  	
  H.P. CONDENSER A OUTLET MOV

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CWS-PL-V003B

  	
   

  	
  H.P. CONDENSER B OUTLET MOV

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  CWS-PY-S01A

  	
   

  	
  CWS TO TCS HX BACKWASH STRAINER A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CWS-PY-S01B

  	
   

  	
  CWS TO TCS HX BACKWASH STRAINER B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  CWS-PY-S01C

  	
   

  	
  CWS TO TCS HX BACKWASH STRAINER C

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  DOS-EH-01A

  	
   

  	
  DOS-MB-01A ELECTRIC HEATER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  DOS-EH-01B

  	
   

  	
  DOS-MB-01A ELECTRIC HEATER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  DOS-EH-02A

  	
   

  	
  DOS-MT-02A ELECTRIC HEATER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  DOS-EH-02B

  	
   

  	
  DOS-MT-02B ELECTRIC HEATER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  DOS-EH-03A

  	
   

  	
  ELECTRIC HEATER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  DOS-EH-03B

  	
   

  	
  ELECTRIC HEATER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  DOS-MP-01A

  	
   

  	
  DIESEL FUEL OIL PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DOS-MP-01B

  	
   

  	
  DIESEL FUEL OIL PUMP B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DOS-MP-02A

  	
   

  	
  AUXILIARY BOILER FUEL OIL PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DOS-MP-02B

  	
   

  	
  AUXILIARY BOILER FUEL OIL PUMP B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DTS-EH-01

  	
   

  	
  CIP Electric Inline Heater

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DTS-MP-01A

  	
   

  	
  RO Unit A Feed Pump

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DTS-MP-01B

  	
   

  	
  RO Unit B Feed Pump

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DTS-MP-03

  	
   

  	
  CIP Pump

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DTS-MP-04

  	
   

  	
  Acid/Salt Injection Pump

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  DTS-MP-05

  	
   

  	
  EDI Brine Pump

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DTS-MP-06

  	
   

  	
  EDI Product Transfer Pump

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DTS-MV-20A

  	
   

  	
  ELECTRODEIONIZATION STACK A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
5 of 20

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Attachment A

 

HOUSE LOADS

EQUIPMENT ON/OFF LIST

 

	
  Tag No.

  	
   

  	
  Component Description

  	
   

  	
  On/Off

  	
   

  	
  Load Note

  	
   

  
	
  DTS-MV-20B

  	
   

  	
  ELECTRODEIONIZATION STACK B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DTS-MV-20C

  	
   

  	
  ELECTRODEIONIZATION STACK C

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DTS-MV-20D

  	
   

  	
  ELECTRODEIONIZATION STACK D

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DWS-EH-01A

  	
   

  	
  DEMINERALIZED WATER STORAGE TANK HEATER A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DWS-EH-01B

  	
   

  	
  DEMINERALIZED WATER STORAGE TANK HEATER B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DWS-EH-02A

  	
   

  	
  CONDENSATE STORAGE TANK HEATER A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DWS-EH-02B

  	
   

  	
  CONDENSATE STORAGE TANK HEATER B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DWS-EH-02C

  	
   

  	
  CONDENSATE STORAGE TANK HEATER C

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DWS-EH-02D

  	
   

  	
  CONDENSATE STORAGE TANK HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DWS-MA-01

  	
   

  	
  DEMIN WTR STOR TK CORS DEGAS BLOWER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DWS-MA-02

  	
   

  	
  Condensate Water Stor Tk CORS Degas Blower

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  DWS-MP-01A

  	
   

  	
  DEMINERALIZED WATER TRANSFER PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DWS-MP-01B

  	
   

  	
  DEMINERALIZED WATER TRANSFER PUMP B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  DWS-MP-02

  	
   

  	
  CORS Feed Pump

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-111

  	
   

  	
  ANNEX BLDG MCC (Rm 40500)

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-112

  	
   

  	
  AUX BLDG MCC (Rm 40500)

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-121

  	
   

  	
  AUX BLDG MCC 121 (Rm 12213)

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-122

  	
   

  	
  TURBINE BLDG MCC 122

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-123

  	
   

  	
  DIESEL GEN BLDG MCC 123

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-124

  	
   

  	
  PZR HTRS BACKUP GRP A MCC 124 (Rm 12321)

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-EC-131

  	
   

  	
  ANNEX BLDG MCC 131 (Rm 40503)

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-132

  	
   

  	
  CONTAINMENT MCC 132 (Rm 12321)

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-133

  	
   

  	
  AUXILIARY BUILDING MCC 133 (Rm 12321)

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-141

  	
   

  	
  ANNEX BLDG MCC 141 (Rm 40413)

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-142

  	
   

  	
  PZR HTRS CONTROL GRP MCC 142 (Rm 12321)

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-EC-143

  	
   

  	
  PZR HTRS BACKUP GRP C MCC 143 (Rm 12321)

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-EC-211

  	
   

  	
  ANNEX BLDG MCC 211 (Rm 40500)

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-212

  	
   

  	
  AUX BLDG MCC 212 (Rm 40500)

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-221

  	
   

  	
  AUX BLDG MCC 221 (Rm 12213)

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-222

  	
   

  	
  TURBINE BLDG MCC 222

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-223

  	
   

  	
  DIESEL GEN BLDG MCC 223

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-224

  	
   

  	
  PZR HTRS BACKUP GRP B MCC 224 (Rm 12321)

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-EC-231

  	
   

  	
  ANNEX BLDG MCC 231 (Rm 40503)

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-232

  	
   

  	
  CONTAINMENT MCC 232 (Rm 12321)

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-233

  	
   

  	
  AUXILIARY BUILDING MCC 233 (Rm 12321)

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-241

  	
   

  	
  ANNEX BLDG MCC 241 (Rm 40357)

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-242

  	
   

  	
  RADWASTE BLDG MCC 242

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-243

  	
   

  	
  PZR HTRS BACKUP GRP D MCC 613 (Rm 12321)

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
6 of 20

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Attachment A

 

HOUSE LOADS

EQUIPMENT ON/OFF LIST

 

	
  Tag No.

  	
   

  	
  Component Description

  	
   

  	
  On/Off

  	
   

  	
  Load Note

  	
   

  
	
  ECS-EC-311

  	
   

  	
  TURBINE BLDG MCC 311

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-312

  	
   

  	
  TURBINE BLDG MCC 312

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-411

  	
   

  	
  TURBINE BLDG MCC 411

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-412

  	
   

  	
  TURBINE BLDG MCC 412

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EC-711

  	
   

  	
  TURBINE BLDG MCC 711

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-EK-11

  	
   

  	
  480 V LOAD CENTER 11

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EK-12

  	
   

  	
  480 V LOAD CENTER 12

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EK-13

  	
   

  	
  480 V LOAD CENTER 13

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EK-14

  	
   

  	
  480 V LOAD CENTER 14

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EK-21

  	
   

  	
  480 V LOAD CENTER 21

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EK-22

  	
   

  	
  480 V LOAD CENTER 22

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EK-23

  	
   

  	
  480 V LOAD CENTER 23

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EK-24

  	
   

  	
  480 V LOAD CENTER 24

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EK-31

  	
   

  	
  480 V LOAD CENTER 31

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EK-41

  	
   

  	
  480 V LOAD CENTER 41

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EK-71

  	
   

  	
  480 V LOAD CENTER 71

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ES-1

  	
   

  	
  6900 V SWITCHGEAR BUS 1

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-ES-2

  	
   

  	
  6900 V SWITCHGEAR BUS 2

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-ES-3

  	
   

  	
  6900 V SWITCHGEAR BUS 3

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-ES-4

  	
   

  	
  6900 V SWITCHGEAR BUS 4

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-ES-5

  	
   

  	
  6900 V SWITCHGEAR BUS 5

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-ES-6

  	
   

  	
  6900 V SWITCHGEAR BUS 6

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-ES-7

  	
   

  	
  6900 V SWITCHGEAR BUS 7

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-ET-1111

  	
   

  	
  ANNEX BUILDING PWR XFMR 1111

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-1121

  	
   

  	
  AUXILIARY BUILDING PWR XFMR 1121

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-1211

  	
   

  	
  AUX BUILDING POWER TRANSFORMER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-1221

  	
   

  	
  TURBINE BUILDING POWER TRANSFORMER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-1231

  	
   

  	
  DIESEL GENERATOR BUILDING POWER TRANSFORMER 1231

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-1311

  	
   

  	
  ANNEX BUILDING PWR XFMR 1311

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-1321

  	
   

  	
  CONTAINMENT POWER TRANSFORMER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-1333

  	
   

  	
  AUXILIARY BUILDING POWER TRANSFORMER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-1411

  	
   

  	
  ANNEX BUILDING PWR XFMR 1411

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-2111

  	
   

  	
  ANNEX BUILDING PWR XFMR 2111

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-2121

  	
   

  	
  AUXILIARY BUILDING PWR XFMR 2121

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-2211

  	
   

  	
  AUX BUILDING POWER TRANSFORMER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-2221

  	
   

  	
  TURBINE BUILDING POWER TRANSFORMER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
7 of 20

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Attachment A

 

HOUSE LOADS

EQUIPMENT ON/OFF LIST

 

	
  Tag No.

  	
   

  	
  Component Description

  	
   

  	
  On/Off

  	
   

  	
  Load Note

  	
   

  
	
  ECS-ET-2231

  	
   

  	
  DIESEL GENERATOR BUILDING POWER TRANSFORMER 2231

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-2311

  	
   

  	
  ANNEX BUILDING PWR XFMR 2311

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-2321

  	
   

  	
  CONTAINMENT POWER TRANSFORMER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-2333

  	
   

  	
  AUXILIARY BUILDING POWER TRANSFORMER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-3111

  	
   

  	
  TURBINE BUILDING POWER TRANSFORMER 3111

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-3121

  	
   

  	
  TURBNIE BUILDING POWER TRANSFORMER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-4111

  	
   

  	
  TURBINE BUILDING POWER TRANSFORMER 4111

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-4121

  	
   

  	
  TURBNIE BUILDING POWER TRANSFORMER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-2411

  	
   

  	
  MACH SHOP DIST XFMR 2411

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-ET-2421

  	
   

  	
  RADWASTE BUILDING POWER TRANSFORMER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-EV-31

  	
   

  	
  RCP 1A Variable Speed Drive Control Power

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EV-41

  	
   

  	
  RCP 1B Variable Speed Drive Control Power

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EV-51

  	
   

  	
  RCP 2A Variable Speed Drive Control Power

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EV-61

  	
   

  	
  RCP 2B Variable Speed Drive Control Power

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ECS-EY-1321

  	
   

  	
  PWR FEED TO 4 CNMT SERVICE MODULE WELDING RECEPT

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-EY-1322

  	
   

  	
  PWR FEED TO 4 CNMT SERVICE MODULE WELDING RECEPT

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-EY-2321

  	
   

  	
  PWR FEED TO 4 CNMT SERVICE MODULE WELDING RECEPT

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ECS-EY-2322

  	
   

  	
  PWR FEED TO 4 CNMT SERVICE MODULE WELDING RECEPT

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  EDS1-DC-1

  	
   

  	
  EDS1 BATTERY CHARGER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  EDS1-DT-1

  	
   

  	
  EDS1 REGULATING XFMR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  EDS2-DC-1

  	
   

  	
  EDS2 BATTERY CHARGER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  EDS2-DT-1

  	
   

  	
  EDS2 REGULATING XFMR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  EDS3-DC-1

  	
   

  	
  EDS3 BATTERY CHARGER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  EDS3-DT-1

  	
   

  	
  EDS3 REGULATING XFMR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  EDS4-DC-1

  	
   

  	
  EDS4 BATTERY CHARGER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  EDSS-DC-1

  	
   

  	
  SPARE NON-1E BATTERY CHARGER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  EHS-EH-01

  	
   

  	
  HEAT TRACING CABINET

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ED-1111

  	
   

  	
  ANNEX BLDG LIGHTING PANEL 1111

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ED-1112

  	
   

  	
  ANNEX BLDG LIGHTING PANEL 1112

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ED-1211

  	
   

  	
  AUXILIARY BUILDING LIGHTING PANEL

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ED-1212

  	
   

  	
  AUXILIARY BUILDING LIGHTING PANEL

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ED-1221

  	
   

  	
  TURBINE BLDG LIGHT PANEL 1221

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ED-1222

  	
   

  	
  TURBINE BLDG LIGHT PANEL 1222

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
8 of 20

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Attachment A

 

HOUSE LOADS

EQUIPMENT ON/OFF LIST

 

	
  Tag No.

  	
   

  	
  Component Description

  	
   

  	
  On/Off

  	
   

  	
  Load Note

  	
   

  
	
  ELS-ED-1223

  	
   

  	
  TURBINE BLDG LIGHT PANEL 1223

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ED-1231

  	
   

  	
  DIESEL GEN BLDG LIGHTING PANEL 1231

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ED-1331

  	
   

  	
  AUXILIARY BUILDING LIGHTING PANEL

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ED-2111

  	
   

  	
  ANNEX BLDG LIGHTING PANEL 2111

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ED-2112

  	
   

  	
  ANNEX BLDG LIGHTING PANEL 2112

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ED-2211

  	
   

  	
  AUXILIARY BUILDING LIGHTING PANEL

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ED-2212

  	
   

  	
  AUXILIARY BUILDING LIGHTING PANEL

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ED-2221

  	
   

  	
  TURBINE BLDG LIGHT PANEL 2221

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ED-2222

  	
   

  	
  TURBINE BLDG LIGHT PANEL 2222

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ED-2223

  	
   

  	
  TURBINE BLDG LIGHT PANEL 2223

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ED-2231

  	
   

  	
  DIESEL GEN BLDG LIGHTING PANEL 2231

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ED-2331

  	
   

  	
  AUXILIARY BUILDING LIGHTING PANEL

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ED-2421

  	
   

  	
  RAD WASTE BLDG LIGHTING PANEL 2421

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ET-1111

  	
   

  	
  ANNEX BLDG LIGHTING XFMR 1111

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ET-1211

  	
   

  	
  AUXILIARY BUILDING LIGHTING TRANSFORMER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ET-1221

  	
   

  	
  TURBINE BLDG LIGHTING XFMR 1221

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ET-1231

  	
   

  	
  DIESEL GEN BLDG LIGHTING XFMR 1231

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ET-1321

  	
   

  	
  CONTAINMENT LIGHTING XFMR 1321

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ET-1322

  	
   

  	
  CONTAINMENT LIGHTING XFMR 1322

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ET-1331

  	
   

  	
  AUXILIARY BUILDING LIGHTING TRANSFORMER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ET-2111

  	
   

  	
  ANNEX BLDG LIGHTING XFMR 2111

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ET-2211

  	
   

  	
  AUXILIARY BUILDING LIGHTING TRANSFORMER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ET-2221

  	
   

  	
  TURBINE BLDG LIGHTING XFMR 2221

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ET-2231

  	
   

  	
  DIESEL GEN BLDG LIGHTING XFMR 2231

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ET-2321

  	
   

  	
  CONTAINMENT LIGHTING XFRMR 2321

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ET-2322

  	
   

  	
  CONTAINMENT LIGHTING XFRMR 2322

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ELS-ET-2331

  	
   

  	
  AUXILIARY BUILDING LIGHTING TRANSFORMER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FHS-EM-01

  	
   

  	
  REFUELING MACHINE MOTOR (IC)

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FHS-EM-02

  	
   

  	
  FUEL HANDLING MACHINE MOTOR (OC)

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FHS-FH-03

  	
   

  	
  NEW FUEL JIB CRANE

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FHS-FH-04

  	
   

  	
  NEW FUEL ELEV & HOIST

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FHS-FH-05

  	
   

  	
  FUEL TRANSFER CONVEYOR (OC)

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FHS-MP-01A

  	
   

  	
  FUEL TRANS UPENDER PUMP (IC)

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FHS-MP-01B

  	
   

  	
  FUEL TRANS UPENDER PUMP (OC)

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FHS-MZ-01

  	
   

  	
  REACTOR VESSEL STUD TENSIONER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FPS-EH-01A-A

  	
   

  	
  PRIMARY FIRE WATER TANK HEATER ELEMENT A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FPS-EH-01A-B

  	
   

  	
  PRIMARY FIRE WATER TANK HEATER ELEMENT B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FPS-EH-01A-C

  	
   

  	
  PRIMARY FIRE WATER TANK HEATER ELEMENT C

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
9 of 20

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Attachment A

 

HOUSE LOADS

EQUIPMENT ON/OFF LIST

 

	
  Tag No.

  	
   

  	
  Component Description

  	
   

  	
  On/Off

  	
   

  	
  Load Note

  	
   

  
	
  FPS-EH-01A-D

  	
   

  	
  PRIMARY FIRE WATER TANK HEATER ELEMENT D

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FPS-EH-01B-A

  	
   

  	
  SECONDARY FIRE WTR/CLEAR WELL TANK HTR ELEMENT A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FPS-EH-01B-B

  	
   

  	
  SECONDARY FIRE WTR/CLEAR WELL TANK HTR ELEMENT B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FPS-EH-01B-C

  	
   

  	
  SECONDARY FIRE WTR/CLEAR WELL TANK HTR ELEMENT C

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FPS-EH-01B-D

  	
   

  	
  SECONDARY FIRE WTR/CLEAR WELL TANK HTR ELEMENT D

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FPS-EH-02

  	
   

  	
  Diesel fire pump enclosure heater

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FPS-MP-01A

  	
   

  	
  MOTOR-DRIVEN FIRE PMP

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FPS-MP-02

  	
   

  	
  JOCKEY PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  FWS-EH-01A

  	
   

  	
  BOOSTER/MAIN FW PUMP A MOTOR HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FWS-EH-01B

  	
   

  	
  BOOSTER/MAIN FW PUMP B MOTOR HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FWS-EH-01C

  	
   

  	
  BOOSTER/MAIN FW PUMP B MOTOR HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FWS-EH-03A

  	
   

  	
  STARTUP FEEDWATER PUMP A MOTOR HEATER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  FWS-EH-03B

  	
   

  	
  STARTUP FEEDWATER PUMP B MOTOR HEATER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  FWS-MP-02A

  	
   

  	
  MAIN FEEDWATER PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FWS-MP-02B

  	
   

  	
  MAIN FEEDWATER PUMP B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  FWS-MP-02C

  	
   

  	
  MAIN FEEDWATER PUMP C

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  FWS-MP-03A

  	
   

  	
  STARTUP FEEDWATER PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FWS-MP-03B

  	
   

  	
  STARTUP FEEDWATER PUMP B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FWS-PL-V004A

  	
   

  	
  Main feedwater pump A discharge isolation valve

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FWS-PL-V004B

  	
   

  	
  Main feedwater pump discharge isolation valve

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FWS-PL-V004C

  	
   

  	
  Main feedwater pump C discharge isolation
  valve

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  FWS-PL-V013A

  	
   

  	
  Sfw pump discharge isolation MOV

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  FWS-PL-V013B

  	
   

  	
  Sfw pump discharge isolation MOV

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  GSS-MA-01A

  	
   

  	
  GLAND CONDENSER VAPOR EXHAUSTER 1A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  GSS-MA-01B

  	
   

  	
  GLAND CONDENSER VAPOR EXHAUSTER 1B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  HCS-EH-01A

  	
   

  	
  Gas Dryer Heater 01A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  HCS-EH-01B

  	
   

  	
  Gas Dryer Heater 01B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  HCS-MA-01A

  	
   

  	
  Gas Dryer Blower 01A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  HCS-MA-01B

  	
   

  	
  Gas Dryer Blower 01B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  HDS-MP-01

  	
   

  	
  MOISTURE SEPARATOR REHEATER SHELL DRAIN PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  HSS-MA-01A

  	
   

  	
  LOOP SEAL VAPOR EXTRACTOR A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  HSS-MA-01B

  	
   

  	
  LOOP SEAL VAPOR EXTRACTOR B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  HSS-MP-01

  	
   

  	
  AIR-SIDE SEAL OIL PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  HSS-MP-03

  	
   

  	
  HYDROGEN-SIDE SEAL OIL PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  IDSA-DC-1

  	
   

  	
  IDSA BATTERY CHARGER 1

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
10 of 20

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Attachment A

 

HOUSE LOADS

EQUIPMENT ON/OFF LIST

 

	
  Tag No.

  	
   

  	
  Component Description

  	
   

  	
  On/Off

  	
   

  	
  Load Note

  	
   

  
	
  IDSA-DT-1

  	
   

  	
  IDSA REGULATING XFMR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  IDSB-DC-1

  	
   

  	
  IDSB BATTERY CHARGER 1

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  IDSB-DC-2

  	
   

  	
  IDSB BATTERY CHARGER 2

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  IDSB-DT-1

  	
   

  	
  IDSB REGULATING XFMR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  IDSC-DC-1

  	
   

  	
  IDSC BATTERY CHARGER 1

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  IDSC-DC-2

  	
   

  	
  IDSC BATTERY CHARGER 2

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  IDSC-DT-1

  	
   

  	
  IDSC REGULATING XFMR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  IDSD-DC-1

  	
   

  	
  IDSD BATTERY CHARGER 1

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  IDSD-DT-1

  	
   

  	
  IDSD REGULATING XFMR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  IDSS-DC-1

  	
   

  	
  SPARE BATTERY CHARGER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  LOS-EH-01

  	
   

  	
  CONDITIONER/PURIFIER UNIT HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  LOS-EH-02

  	
   

  	
  CONDITIONER/PURIFIER UNIT HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  LOS-MA-01A

  	
   

  	
  VAPOR EXTRACTOR A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  LOS-MA-01B

  	
   

  	
  VAPOR EXTRACTOR B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  LOS-MP-02

  	
   

  	
  AC BEARING OIL PUMP

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  LOS-MP-04

  	
   

  	
  AC SEAL OIL BACKUP PUMP

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  LOS-MP-05

  	
   

  	
  Clean Oil Transfer Pump

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  LOS-MP-10A

  	
   

  	
  LP BEARING LIFT OIL PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  LOS-MP-10B

  	
   

  	
  LP BEARING LIFT OIL PUMP B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  LOS-MP-10C

  	
   

  	
  LP BEARING LIFT OIL PUMP C

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  LOS-MP-10D

  	
   

  	
  LP BEARING LIFT OIL PUMP D

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  LOS-MP-10E

  	
   

  	
  LP BEARING LIFT OIL PUMP E

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  LOS-MP-10F

  	
   

  	
  LP BEARING LIFT OIL PUMP F

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  LOS-MP-11

  	
   

  	
  VACUUM CONDITIONING UNIT DRAIN PUMP

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  LOS-MP-12

  	
   

  	
  CONDITIONER/PURIFIER UNIT SUPPLY PUMP

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  LOS-MP-13

  	
   

  	
  CONDITIONER/PURIFIER UNIT VACUUM PUMP

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MHS-MH-01

  	
   

  	
  CONTAINMENT POLAR CRANE

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MHS-MH-02

  	
   

  	
  SPENT FUEL SHIPPING CASK CRANE

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MHS-MH-03

  	
   

  	
  STEAM GENERATOR 1 JIB CRANE

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MHS-MH-04

  	
   

  	
  STEAM GENERATOR 2 JIB CRANE

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MHS-MH-05

  	
   

  	
  EQUIPMENT HATCH HOIST

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MHS-MH-06

  	
   

  	
  MAINTENANCE HATCH HOIST

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MHS-MH-07A

  	
   

  	
  MSIV MONORAIL HOIST A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MHS-MH-07B

  	
   

  	
  MSIV MONORAIL HOIST B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
11 of 20

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Attachment A

 

HOUSE LOADS

EQUIPMENT ON/OFF LIST

 

	
  Tag No.

  	
   

  	
  Component Description

  	
   

  	
  On/Off

  	
   

  	
  Load Note

  	
   

  
	
  MHS-MH-09

  	
   

  	
  CONTAINMENT ELEVATOR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MHS-MH-11

  	
   

  	
  SHIELD BUILDING EXTERNAL ELEVATOR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MHS-MH-12

  	
   

  	
  AUXILIARY BUILDING CLEAN SIDE ELEVATOR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MHS-MH-13

  	
   

  	
  AUXILIARY BUILDING RADIATION CONTROL AREA ELEV

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MHS-MH-14

  	
   

  	
  RAIL CAR BAY CRANE AND CONSOLE

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  MHS-MH-20

  	
   

  	
  TURBINE BUILDING BRIDGE CRANE

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  MHS-MH-21

  	
   

  	
  TURBINE BUILDING SECONDARY BRIDGE CRANE

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MHS-MH-23

  	
   

  	
  TURBINE BUILDING ELEVATOR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MHS-MH-40

  	
   

  	
  ANNEX BUILDING STAGING AREA CRANE

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MHS-MH-41

  	
   

  	
  ANNEX BUILDING HOT MACHINE SHOP CRANE

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MHS-MH-42

  	
   

  	
  BORIC ACID HANDLING MONORAIL

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MHS-MH-45

  	
   

  	
  ANNEX BUILDING ELEVATOR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MHS-MH-50

  	
   

  	
  MOBILE SYSTEMS FACILITY CRANE

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MHS-MH-51

  	
   

  	
  CLOSED VAN LOADING SCISSOR LIFT (PORTABLE)

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MSS-PL-V015

  	
   

  	
  MSR reheat supply steam isolation MOV

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  MSS-PL-V025

  	
   

  	
  MSS supply to gland seal system - isolation MOV

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MSS-PL-V501

  	
   

  	
  EXT STEAM TO HEATER 7 MOV

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MSS-PL-V502

  	
   

  	
  EXT STEAM TO HEATER 6 MOV

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MSS-PL-V503

  	
   

  	
  EXT STEAM TO DEA HTR 5 MOV

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MSS-PL-V504

  	
   

  	
  EXT STEAM TO HEATER 4 MOV

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MSS-PL-V505

  	
   

  	
  EXT STEAM TO HEATER 3 MOV

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  MSS-PL-V577

  	
   

  	
  MSS to VYS isolation MOV

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  MTS-EM-01

  	
   

  	
  MAIN TRBN TURNING GEAR MTR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  PCS-EH-01

  	
   

  	
  RECIRCULATION HEATER ELEMENT

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  PCS-EH-02A

  	
   

  	
  Ancillary Water Storage Tank Heater Element A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  PCS-EH-02B

  	
   

  	
  Ancillary Water Storage Tank Heater Element B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  PCS-EH-02C

  	
   

  	
  Ancillary Water Storage Tank Heater Element C

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  PCS-EH-02D

  	
   

  	
  Ancillary Water Storage Tank Heater Element D

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  PCS-MP-01A

  	
   

  	
  RECIRCULATION PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  PCS-MP-01B

  	
   

  	
  RECIRCULATION PUMP B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  PGS-ME-07

  	
   

  	
  CARBON DIOXIDE ELECTRIC VAPORIZER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  PGS-MP-01

  	
   

  	
  LIQUID NITROGEN PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  PGS-MS-03

  	
   

  	
  CARBON DIOXIDE PACKAGE

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  PLS-MG-01A

  	
   

  	
  ROD DRIVE M/G SET A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  PLS-MG-01B

  	
   

  	
  ROD DRIVE M/G SET B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
12 of 20

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Attachment A

 

HOUSE LOADS

EQUIPMENT ON/OFF LIST

 

	
  Tag No.

  	
   

  	
  Component Description

  	
   

  	
  On/Off

  	
   

  	
  Load Note

  	
   

  
	
  PSS-MP-01

  	
   

  	
  EDUCTOR SUPPLY PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  PWS-MP-01A

  	
   

  	
  POTABLE WATER SUPPLY PUMP A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  PWS-MP-01B

  	
   

  	
  POTABLE WATER SUPPLY PUMP B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  PWS-MP-02

  	
   

  	
  POTABLE WATER JOCKEY PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  PXS-PL-V027A

  	
   

  	
  Accum A Discharge Isolation

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  PXS-PL-V027B

  	
   

  	
  Accum B Discharge Isolation

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  PXS-PL-V121A

  	
   

  	
  IRWST Line A Isolation

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  PXS-PL-V121B

  	
   

  	
  IRWST Line B Isolation

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  RCS-EH-03-1

  	
   

  	
  Pressurizer Heaters –Control Group, Bank 1

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  RCS-EH-03-2

  	
   

  	
  Pressurizer Heaters –Control Group, Bank 2

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-03-3

  	
   

  	
  Pressurizer Heaters –Control Group, Bank 3

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-03-4

  	
   

  	
  Pressurizer Heaters –Control Group, Bank 4

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-03-5

  	
   

  	
  Pressurizer Heaters –Control Group, Bank 5

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-03-6

  	
   

  	
  Pressurizer Heaters –Control Group, Bank 6

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04A-1

  	
   

  	
  Pressurizer Heaters –Control Group A, Bank
  1

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04A-2

  	
   

  	
  Pressurizer Heaters –Control Group A, Bank
  2

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04A-3

  	
   

  	
  Pressurizer Heaters –Control Group A, Bank
  3

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04A-4

  	
   

  	
  Pressurizer Heaters –Control Group A, Bank
  4

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04B-1

  	
   

  	
  Pressurizer Heaters –Control Group B, Bank
  1

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04B-2

  	
   

  	
  Pressurizer Heaters –Control Group B, Bank
  2

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04B-3

  	
   

  	
  Pressurizer Heaters –Control Group B, Bank
  3

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04B-4

  	
   

  	
  Pressurizer Heaters –Control Group B, Bank
  4

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04C-1

  	
   

  	
  Pressurizer Heaters –Control Group C, Bank
  1

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04C-2

  	
   

  	
  Pressurizer Heaters –Control Group C, Bank
  2

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04C-3

  	
   

  	
  Pressurizer Heaters –Control Group C, Bank
  3

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04C-4

  	
   

  	
  Pressurizer Heaters –Control Group C, Bank
  4

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04C-5

  	
   

  	
  Pressurizer Heaters –Control Group C, Bank
  5

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04C-6

  	
   

  	
  Pressurizer Heaters –Control Group C, Bank
  6

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04D-1

  	
   

  	
  Pressurizer Heaters –Control Group D, Bank
  1

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04D-2

  	
   

  	
  Pressurizer Heaters –Control Group D, Bank
  2

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04D-3

  	
   

  	
  Pressurizer Heaters –Control Group D, Bank
  3

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04D-4

  	
   

  	
  Pressurizer Heaters –Control Group D, Bank
  4

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04D-5

  	
   

  	
  Pressurizer Heaters –Control Group Bank 5

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-EH-04D-6

  	
   

  	
  Pressurizer Heaters –Control Group D, Bank
  6

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-MP-01A

  	
   

  	
  SG 1A RX COOLANT PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-MP-01B

  	
   

  	
  SG 1B RX COOLANT PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-MP-02A

  	
   

  	
  SG 2A RX COOLANT PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-MP-02B

  	
   

  	
  SG 2B RX COOLANT PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RCS-PL-V111A

  	
   

  	
  Pressurizer Spray Block Valve

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
13 of 20

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Attachment A

 

HOUSE LOADS

EQUIPMENT ON/OFF LIST

 

	
  Tag No.

  	
   

  	
  Component Description

  	
   

  	
  On/Off

  	
   

  	
  Load Note

  	
   

  
	
  RCS-PL-V111B

  	
   

  	
  Pressurizer Spray Block Valve

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  RNS-MP-01A

  	
   

  	
  RESIDUAL HEAT REMOVAL PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  RNS-MP-01B

  	
   

  	
  RESIDUAL HEAT REMOVAL PUMP B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  RNS-PL-V024

  	
   

  	
  RNS Discharge to IRWST Isolation

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  RNS-PL-V055

  	
   

  	
  RNS Suction from Cask Loading Pit Isol
  Valve

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RWS-EH-03A

  	
   

  	
  RAW WATER PUMP A MOTOR HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  RWS-EH-03B

  	
   

  	
  RAW WATER PUMP B MOTOR HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  RWS-EH-03C

  	
   

  	
  RAW WATER PUMP C MOTOR HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  RWS-MP-03A

  	
   

  	
  RAW WATER PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  RWS-MP-03B

  	
   

  	
  RAW WATER PUMP B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  RWS-MP-03C

  	
   

  	
  RAW WATER PUMP C

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  RWS-Ancillary Pump A

  	
   

  	
  RWS Ancillary Pump A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  RWS-Ancillary Pump B

  	
   

  	
  RWS Ancillary Pump B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RWS-MP-04A

  	
   

  	
  CLEARWELL PUMP A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RWS-MP-04B

  	
   

  	
  CLEARWELL PUMP B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  RXS-MA-01A

  	
   

  	
  CRDM COOLING FAN A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  RXS-MA-01B

  	
   

  	
  CRDM COOLING FAN B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  RXS-MA-01C

  	
   

  	
  CRDM COOLING FAN C

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  SFS-MP-01A

  	
   

  	
  SPENT FUEL COOLING PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  SFS-MP-01B

  	
   

  	
  SPENT FUEL COOLING PUMP B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  SSS-MS-01

  	
   

  	
  CONDENSER HOTWELL PUMP PACKAGE

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  SSS-MS-02

  	
   

  	
  SECONDARY SAMPLING PACKAGE

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  SSS-MS-04

  	
   

  	
  COOLING WATER PACKAGE

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  SWS-EH-01A

  	
   

  	
  Service Water Pump A Motor Heater

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  SWS-EH-01B

  	
   

  	
  Service Water Pump B Motor Heater

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  SWS-EH-02A

  	
   

  	
  Service Water Pump A Motor Heater

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  SWS-EH-02B

  	
   

  	
  Service Water Pump B Motor Heater

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  SWS-MA-01A

  	
   

  	
  SERVICE WATER COOLING TOWER FAN A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  SWS-MA-01B

  	
   

  	
  SERVICE WATER COOLING TOWER FAN B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  SWS-MP-01A

  	
   

  	
  SERVICE WATER PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  SWS-MP-01B

  	
   

  	
  SERVICE WATER PUMP B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  SWS-PL-V002A

  	
   

  	
  SWS Pump A Discharge MOV

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  SWS-PL-V002B

  	
   

  	
  SWS Pump B Discharge MOV

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  SWS-PL-V037A

  	
   

  	
  SWS Cooling Tower A MOV

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 14 of 20

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Attachment A

 

HOUSE LOADS

EQUIPMENT ON/OFF LIST

 

	
  Tag No.

  	
   

  	
  Component Description

  	
   

  	
  On/Off

  	
   

  	
  Load Note

  	
   

  
	
  SWS-PL-V037B

  	
   

  	
  SWS Cooling Tower B MOV

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  SWS-PY-S06A

  	
   

  	
  SWS SELF CLEANING STRAINER A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  SWS-PY-S06B

  	
   

  	
  SWS SELF CLEANING STRAINER B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  TCS-EH-01A

  	
   

  	
  TCS PUMP A MOTOR HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  TCS-EH-01B

  	
   

  	
  TCS PUMP B MOTOR HEATER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  TCS-MP-01A

  	
   

  	
  TURBINE BUILDING CLOSED COOLING WATER PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  TCS-MP-01B

  	
   

  	
  TURBINE BUILDING CLOSED COOLING WATER PUMP B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  TOS-EH-01

  	
   

  	
  EH FLUID RESERVOIR IMMERSION HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  TOS-MA-01A

  	
   

  	
  EH FLUID HX COOLING FAN A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  TOS-MA-01B

  	
   

  	
  EH FLUID HX COOLING FAN B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  TOS-MP-01A

  	
   

  	
  ELECTRO-HYDRAULIC FLUID SUPPLY PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  TOS-MP-01B

  	
   

  	
  ELECTRO-HYDRAULIC FLUID SUPPLY PUMP B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VAS-EH-01A

  	
   

  	
  RADIATION CHEMISTRY LABORATORY DUCT HEATER STAGE A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VAS-EH-01B

  	
   

  	
  RADIATION CHEMISTRY LABORATORY DUCT HEATER STAGE B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VAS-EH-02A

  	
   

  	
  SECURITY ROOM DUCT HEATER STAGE A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VAS-EH-02B

  	
   

  	
  SECURITY ROOM DUCT HEATER STAGE B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VAS-MA-01A

  	
   

  	
  AUXILIARY/ANNEX BUILDING SUPPLY FAN A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VAS-MA-01B

  	
   

  	
  AUXILIARY/ANNEX BUILDING SUPPLY FAN B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VAS-MA-02A

  	
   

  	
  AUXILIARY/ANNEX BUILDING EXHAUST FAN A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VAS-MA-02B

  	
   

  	
  AUXILIARY/ANNEX BUILDING EXHAUST FAN B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VAS-MA-05A

  	
   

  	
  FUEL HANDLING AREA SUPPLY FAN A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VAS-MA-05B

  	
   

  	
  FUEL HANDLING AREA SUPPLY FAN B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VAS-MA-06A

  	
   

  	
  FUEL HANDLING AREA EXHAUST FAN A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VAS-MA-06B

  	
   

  	
  FUEL HANDLING AREA EXHAUST FAN B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VAS-MA-07A

  	
   

  	
  CHEMICAL VOLUME CONTROL SYSTEM PUMP ROOM FAN A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VAS-MA-07B

  	
   

  	
  CHEMICAL VOLUME CONTROL SYSTEM PUMP ROOM FAN B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VAS-MA-08A

  	
   

  	
  NORMAL RESIDUAL HEAT REMOVAL PUMP ROOM FAN A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VAS-MA-08B

  	
   

  	
  NORMAL RESIDUAL HEAT REMOVAL PUMP ROOM FAN B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VAS-MY-H01

  	
   

  	
  RADIATION CHEMISTRY LABORATORY HUMIDIFIER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VAS-MY-H02

  	
   

  	
  SECURITY ROOM HUMIDIFIER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VAS-MY-U01A

  	
   

  	
  Middle Annulus Heater A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VAS-MY-U01B

  	
   

  	
  Middle Annulus Heater B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VAS-MY-U01C

  	
   

  	
  Middle Annulus Heater C

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VAS-MY-U01D

  	
   

  	
  Middle Annulus Heater D

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-EH-01A

  	
   

  	
  MCR/TSC AHU ELECTRIC HEATER A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-EH-01B

  	
   

  	
  MCR/TSC AHU ELECTRIC HEATER B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-EH-02A

  	
   

  	
  A/C 1E ROOM AHU ELEC HTR A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 15 of 20

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Attachment A

 

HOUSE LOADS

EQUIPMENT ON/OFF LIST

 

	
  Tag No.

  	
   

  	
  Component Description

  	
   

  	
  On/Off

  	
   

  	
  Load Note

  	
   

  
	
  VBS-EH-02B

  	
   

  	
  B/D 1E ROOM AHU ELEC HTR B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-EH-02C

  	
   

  	
  A/C 1E ROOM AHU ELEC HTR C

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-EH-02D

  	
   

  	
  B/D 1E ROOM AHU ELEC HTR D

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-EH-04A

  	
   

  	
  FILTER UNIT ELECTRIC HTR A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-EH-04B

  	
   

  	
  FILTER UNIT ELECTRIC HTR B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-MA-01A

  	
   

  	
  MCR/TSC AHU SUPPLY FAN A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-MA-01B

  	
   

  	
  MCR/TSC AHU SUPPLY FAN B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-MA-02A

  	
   

  	
  MCR/TSC AHU RETURN AND SMOKE PURGE FAN A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-MA-02B

  	
   

  	
  MCR/TSC AHU RETURN AND SMOKE PURGE FAN B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-MA-03A

  	
   

  	
  SUPPLEMENTAL AIR FILTRATION UNIT FAN A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-MA-03B

  	
   

  	
  SUPPLEMENTAL AIR FILTRATION UNIT FAN B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-MA-04

  	
   

  	
  MCR TOILET EXHAUST FAN

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VBS-MA-05A

  	
   

  	
  A/C 1E ROOM AHU SUPPLY FAN A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-MA-05B

  	
   

  	
  B/D 1E ROOM AHU SUPPLY FAN B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VBS-MA-05C

  	
   

  	
  A/C 1E ROOM AHU SUPPLY FAN C

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-MA-05D

  	
   

  	
  B/D 1E ROOM AHU SUPPLY FAN D

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-MA-06A

  	
   

  	
  A/C 1E ROOM - RETURN FAN A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-MA-06B

  	
   

  	
  B/D 1E ROOM RETURN FAN B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VBS-MA-06C

  	
   

  	
  A/C 1E ROOM RETURN FAN C

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-MA-06D

  	
   

  	
  B/D 1E ROOM - RETURN FAN D

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-MA-07A

  	
   

  	
  A/C BATTERY ROOM EXH FAN A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-MA-07B

  	
   

  	
  B/D BATTERY ROOM EXH FAN B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VBS-MA-07C

  	
   

  	
  A/C BATTERY ROOM EXH FAN C

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VBS-MA-07D

  	
   

  	
  B/D BATTERY ROOM EXH FAN D

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-MA-08

  	
   

  	
  PCS VALVE ROOM VENT FAN

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VBS-MA-09

  	
   

  	
  TSC TOILET EXHAUST FAN

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VBS-MY-H01A

  	
   

  	
  MCR/TSC AHU HUMIDIFIER A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-MY-H01B

  	
   

  	
  MCR/TSC AHU HUMIDIFIER B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-MY-U01A

  	
   

  	
  PCS VALVE ROOM UNIT HEATER A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VBS-MY-U01B

  	
   

  	
  PCS VALVE ROOM UNIT HEATER B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VCS-MA-01A

  	
   

  	
  REACTOR CONTAINMENT RECIRCULATION FAN A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VCS-MA-01B

  	
   

  	
  REACTOR CONTAINMENT RECIRCULATION FAN B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VCS-MA-01C

  	
   

  	
  REACTOR CONTAINMENT RECIRCULATION FAN C

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VCS-MA-01D

  	
   

  	
  REACTOR CONTAINMENT RECIRCULATION FAN D

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VFS-EH-01A

  	
   

  	
  CONTAINMENT EXHAUST ELECTRIC HEATER A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VFS-EH-01B

  	
   

  	
  CONTAINMENT EXHAUST ELECTRIC HEATER B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VFS-MA-01A

  	
   

  	
  CONTAINMENT SUPPLY FAN A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VFS-MA-01B

  	
   

  	
  CONTAINMENT SUPPLY FAN B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VFS-MA-02A

  	
   

  	
  CONTAINMENT EXHAUST FAN A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 16 of 20

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Attachment A

 

HOUSE LOADS

EQUIPMENT ON/OFF LIST

 

	
  Tag No.

  	
   

  	
  Component Description

  	
   

  	
  On/Off

  	
   

  	
  Load Note

  	
   

  
	
  VFS-MA-02B

  	
   

  	
  CONTAINMENT EXHAUST FAN B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VHS-MA-01A

  	
   

  	
  AHU A SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VHS-MA-01B

  	
   

  	
  AHU B SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VHS-MA-02A

  	
   

  	
  HEALTH PHYSICS/MACHINE SHOP EXHAUST FAN A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VHS-MA-02B

  	
   

  	
  HEALTH PHYSICS/MACHINE SHOP EXHAUST FAN B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VHS-MA-03

  	
   

  	
  MACHINE TOOLS EXHAUST FAN

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VHS-MY-H01

  	
   

  	
  HUMIDIFIER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VRS-MA-01A

  	
   

  	
  AHU A SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VRS-MA-01B

  	
   

  	
  AHU B SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VRS-MA-02A

  	
   

  	
  FILTRATION UNIT A EXH FAN

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VRS-MA-02B

  	
   

  	
  FILTRATION UNIT B EXH FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VRS-MY-W01A

  	
   

  	
  MOBILE SYSTEM FACILITY HOT WATER UNIT HEATER A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VRS-MY-W01B

  	
   

  	
  MOBILE SYSTEM FACILITY HOT WATER UNIT HEATER B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VRS-MY-W01C

  	
   

  	
  MOBILE SYSTEM FACILITY HOT WATER UNIT HEATER C

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VTS-EH-01

  	
   

  	
  SAMPLE ROOM / LABORATORY DUCT HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VTS-EH-03

  	
   

  	
  OFFICE AREA DUCT HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VTS-EH-04

  	
   

  	
  WORK STATION AREA DUCT HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VTS-MA-01A

  	
   

  	
  PERSONNEL AREA AHU A SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VTS-MA-01B

  	
   

  	
  PERSONNEL AREA AHU B SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VTS-MA-05A

  	
   

  	
  EL EQ RM AHU A RETURN FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VTS-MA-05B

  	
   

  	
  EL EQ RM AHU B RETURN FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VTS-MA-06A

  	
   

  	
  EL EQ RM AHU A SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VTS-MA-06B

  	
   

  	
  EL EQ RM AHU B SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VTS-MA-13

  	
   

  	
  TURBINE LUBE OIL RESERVOIR ROOM EXHAUST FAN

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VTS-MA-14

  	
   

  	
  LUBE OIL STORAGE ROOM EXHAUST FAN

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VTS-MY-V01A

  	
   

  	
  TRBN BLDG ROOF EXH UNIT VENT A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VTS-MY-V01B

  	
   

  	
  TRBN BLDG ROOF EXH UNIT VENT B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VTS-MY-V01C

  	
   

  	
  TRBN BLDG ROOF EXH UNIT VENT C

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VTS-MY-V01D

  	
   

  	
  TRBN BLDG ROOF EXH UNIT VENT D

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VTS-MY-V01E

  	
   

  	
  TRBN BLDG ROOF EXH UNIT VENT E

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VTS-MY-V01F

  	
   

  	
  TRBN BLDG ROOF EXH UNIT VENT F

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VTS-MY-V02

  	
   

  	
  HEATER BAY ROOF EXH UNIT VENT

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VTS-MY-V03

  	
   

  	
  MOTOR DRIVEN FIRE PUMP ROOM UNIT VENTILATOR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VTS-MY-V04

  	
   

  	
  DIESEL FIRE PUMP ROOM UNIT VENTILATOR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VTS-MY-V05A

  	
   

  	
  AUX BOILER ROOM EXHAUST VENTILATOR A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VTS-MY-V05B

  	
   

  	
  AUX BOILER ROOM EXHAUST VENTILATOR B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VWS-MP-01A

  	
   

  	
  WATER CHILLER PUMP A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VWS-MP-01B

  	
   

  	
  WATER CHILLER PUMP B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 17 of 20

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Attachment A

 

HOUSE LOADS

EQUIPMENT ON/OFF LIST

 

	
  Tag No.

  	
   

  	
  Component Description

  	
   

  	
  On/Off

  	
   

  	
  Load Note

  	
   

  
	
  VWS-MP-02

  	
   

  	
  AIR COOLED CHILLER PUMP 2

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VWS-MP-03

  	
   

  	
  AIR COOLED CHILLER PUMP 3

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VWS-MS-01A

  	
   

  	
  WATER CHILLER A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VWS-MS-01B

  	
   

  	
  WATER CHILLER B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VWS-MS-02

  	
   

  	
  AIR COOLED CHILLER 2

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VWS-MS-03

  	
   

  	
  AIR COOLED CHILLER 3

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-EH-02

  	
   

  	
  REST ROOM/CORRIDOR ELECT HEATING COIL

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-EH-03

  	
   

  	
  ACCESS CORRIDOR ELECTRIC DUCT HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-EH-04

  	
   

  	
  SECURITY ROOM #2 ELECTRIC DUCT HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-EH-05

  	
   

  	
  CENTRAL ALARM STATION ELECTRIC DUCT HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-EH-06

  	
   

  	
  SHOWER/CHANGING AREA ELECTRIC DUCT HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-MA-01A

  	
   

  	
  EQUIPMENT ROOM RETURN AIR FAN A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-MA-01B

  	
   

  	
  EQUIPMENT ROOM RETURN AIR FAN B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-MA-02A

  	
   

  	
  EQUIPMENT ROOM AHU A SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-MA-02B

  	
   

  	
  EQUIPMENT ROOM AHU B SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-MA-03A

  	
   

  	
  GENERAL AREA AHU A SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VXS-MA-03B

  	
   

  	
  GENERAL AREA AHU B SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-MA-04A

  	
   

  	
  MSIV COMP A AHU-A SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-MA-04B

  	
   

  	
  MSIV COMP B AHU-B SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-MA-04C

  	
   

  	
  MSIV COMP B AHU-C SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-MA-04D

  	
   

  	
  MSIV COMP A AHU-D SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-MA-05A

  	
   

  	
  SWITCHGEAR ROOM AHU A SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-MA-05B

  	
   

  	
  SWITCHGEAR ROOM AHU B SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-MA-06A

  	
   

  	
  SWITCHGEAR ROOM RETURN AIR FAN A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-MA-06B

  	
   

  	
  SWITCHGEAR ROOM RETURN AIR FAN B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-MA-07A

  	
   

  	
  MECHANICAL EQUIPMENT ROOM SUPPLY AIR FAN A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VXS-MA-07B

  	
   

  	
  MECHANICAL EQUIPMENT ROOM SUPPLY AIR FAN B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-MA-08A

  	
   

  	
  VLV/PIPING PEN RM AHU A SUPP FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-MA-08B

  	
   

  	
  VLV/PIPING PEN RM AHU B SUPP FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-MA-09A

  	
   

  	
  BATTERY ROOM #1 EXH FAN

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VXS-MA-09B

  	
   

  	
  BATTERY ROOM #2 EHX FAN

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VXS-MA-11A

  	
   

  	
  MECH EQP AREA AHU A RETURN AIR FAN

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VXS-MA-11B

  	
   

  	
  MECH EQP AREA AHU B RETURN AIR FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-MA-12

  	
   

  	
  Temp Electric Power Supply Room Exhaust Fan

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VXS-MA-13

  	
   

  	
  TOILET EXHAUST FAN

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VXS-MY-H01

  	
   

  	
  GENERAL AREA AHU HUMIDIFIER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VXS-MY-H02

  	
   

  	
  EQUIPMENT ROOM AHU HUMIDIFIER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VXS-MY-U01

  	
   

  	
  ELEVATOR MACHINE ROOM ELEC UNIT HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VXS-MY-V01

  	
   

  	
  ELEVATOR MACHINE ROOM WALL EXHAUSTER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 18 of 20

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Attachment A

 

HOUSE LOADS

EQUIPMENT ON/OFF LIST

 

	
  Tag No.

  	
   

  	
  Component Description

  	
   

  	
  On/Off

  	
   

  	
  Load Note

  	
   

  
	
  VXS-MY-V02

  	
   

  	
  ANNEX BLDG ROOF VENTILATOR

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VYS-MP-01A

  	
   

  	
  HOT WATER PUMP A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VYS-MP-01B

  	
   

  	
  HOT WATER PUMP B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VZS-EH-01A

  	
   

  	
  SRVC MODULE AHU A ELEC HTNG COIL

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VZS-EH-01B

  	
   

  	
  SRVC MODULE AHU B ELEC HTNG COIL

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VZS-MA-01A

  	
   

  	
  SERVICE MODULE AHU A SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VZS-MA-01B

  	
   

  	
  SERVICE MODULE AHU B SUPPLY FAN

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VZS-MA-02A

  	
   

  	
  FUEL OIL DAY TK VAULT EXH FAN A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VZS-MA-02B

  	
   

  	
  FUEL OIL DAY TK VAULT EXH FAN B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VZS-MA-03A

  	
   

  	
  ENGINE ROOM AHU SUPPLY FAN A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VZS-MA-03B

  	
   

  	
  ENGINE ROOM AHU SUPPLY FAN B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VZS-MY-U01A

  	
   

  	
  ELECTRIC UNIT HEATER 1A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VZS-MY-U01B

  	
   

  	
  ELECTRIC UNIT HEATER 1B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VZS-MY-U02A

  	
   

  	
  ELECTRIC UNIT HEATER 2A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VZS-MY-U02B

  	
   

  	
  ELECTRIC UNIT HEATER 2B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VZS-MY-U03A

  	
   

  	
  DIESEL OIL TRANSFER MODULE ENCLOSURE A UNIT HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VZS-MY-U03B

  	
   

  	
  DIESEL OIL TRANSFER MODULE ENCLOSURE B UNIT HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VZS-MY-V01A

  	
   

  	
  D/G BLDG STANDBY EXHAUST FAN 1A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VZS-MY-V01B

  	
   

  	
  D/G BLDG STANDBY EXHAUST FAN 1B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VZS-MY-V02A

  	
   

  	
  D/G BLDG STANDBY EXHAUST FAN 2A

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VZS-MY-V02B

  	
   

  	
  D/G BLDG STANDBY EXHAUST FAN 2B

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  VZS-MY-V03A

  	
   

  	
  DIESEL OIL TRANSFER MODULE ENCLOSURE A EXH FAN

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  VZS-MY-V03B

  	
   

  	
  DIESEL OIL TRANSFER MODULE ENCLOSURE B EXH FAN

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  WGS-MP-01A

  	
   

  	
  SAMPLE PUMP A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  WGS-MP-01B

  	
   

  	
  SAMPLE PUMP B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  WLS-MP-01A

  	
   

  	
  REACTOR COOLANT DRAIN PUMP A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  WLS-MP-01B

  	
   

  	
  REACTOR COOLANT DRAIN PUMP B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  WLS-MP-02A

  	
   

  	
  CONTAINMENT SUMP PUMP A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  WLS-MP-02B

  	
   

  	
  CONTAINMENT SUMP PUMP B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  WLS-MP-03A

  	
   

  	
  DEGASIFIER VACUUM PUMP A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  WLS-MP-03B

  	
   

  	
  DEGASIFIER VACUUM PUMP B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  WLS-MP-05A

  	
   

  	
  DEGASIFIER SEPARATOR PUMP A

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  WLS-MP-05B

  	
   

  	
  DEGASIFIER SEPARATOR PUMP B

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  WSS-MP-01

  	
   

  	
  RESIN TRANSFER PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  WWS-MP-04A

  	
   

  	
  BASIN A TRANSFER PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  WWS-MP-04B

  	
   

  	
  BASIN B TRANSFER PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ZAS-EJ-01A

  	
   

  	
  MAIN TRANS COOLING PHASE A JUNCTION BOX

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ZAS-EJ-01B

  	
   

  	
  MAIN TRANS COOLING PHASE B JUNCTION BOX

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ZAS-EJ-01C

  	
   

  	
  MAIN TRANS COOLING PHASE C JUNCTION BOX

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 19 of 20

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Attachment A

 

HOUSE LOADS

EQUIPMENT ON/OFF LIST

 

	
  Tag No.

  	
   

  	
  Component Description

  	
   

  	
  On/Off

  	
   

  	
  Load Note

  	
   

  
	
  ZAS-EJ-01D

  	
   

  	
  MAIN TRANS COOLING PHASE SPARE JUNCTION BOX

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ZAS-EJ-02A

  	
   

  	
  GEN BKR COOLING UNIT PHASE A JUNCTION BOX

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ZAS-EJ-02B

  	
   

  	
  GEN BKR COOLING UNIT PHASE B JUNCTION BOX

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ZAS-EJ-02C

  	
   

  	
  GEN BKR COOLING UNIT PHASE C JUNCTION BOX

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ZAS-EJ-03

  	
   

  	
  ISOPHASE BUS DUCT HEATER UNIT JUNCTION BOX

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ZBS-ED-01

  	
   

  	
  SWITCHYARD FEED #1 DIST PANEL

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ZBS-ED-02

  	
   

  	
  SWITCHYARD FEED #2 DIST PANEL

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ZOS-EH-01A

  	
   

  	
  DG A ELECTRIC JACKET WATER HTR

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ZOS-EH-01B

  	
   

  	
  DG B ELECTRIC JACKET WATER HTR

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ZOS-EH-02A

  	
   

  	
  DG A KEEP WARM LUBE OIL HEATER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ZOS-EH-02B

  	
   

  	
  DG B KEEP WARM LUBE OIL HEATER

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ZOS-EH-03A

  	
   

  	
  DG A GENERATOR SPACE HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ZOS-EH-03B

  	
   

  	
  DG B GENERATOR SPACE HEATER

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ZOS-MA-01A

  	
   

  	
  DG A FUEL OIL COOLER FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ZOS-MA-01B

  	
   

  	
  DG B FUEL OIL COOLER FAN

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ZOS-MA-10A

  	
   

  	
  DG A RADIATOR FAN 1

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ZOS-MA-10B

  	
   

  	
  DG B RADIATOR FAN 1

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ZOS-MA-11A

  	
   

  	
  DG A RADIATOR FAN 2

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ZOS-MA-11B

  	
   

  	
  DG B RADIATOR FAN 2

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ZOS-MK-01A

  	
   

  	
  DG A ELECTRIC MTR DRVN AIR COMPRESSOR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ZOS-MK-01B

  	
   

  	
  DG B ELECTRIC MTR DRVN AIR COMPRESSOR

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  
	
  ZOS-MP-02A

  	
   

  	
  DG A AC MOTOR PRELUBE OIL PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ZOS-MP-02B

  	
   

  	
  DG B AC MOTOR PRELUBE OIL PUMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ZOS-MP-06A

  	
   

  	
  DG A ELECTRIC JACKET WTR HTR PMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
  ZOS-MP-06B

  	
   

  	
  DG B ELECTRIC JACKET WTR HTR PMP

  	
   

  	
  [**]

  	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
   

  	
  Site Specific Load

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  N/A

  	
   

  	
  200 HP Mechanical Draft Cooling Tower Fans

  	
   

  	
  [**]

  	
   

  	
  [**]

  	
   

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 20 of 20

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

EXHIBIT M-1

 

Software License

 

This software license
agreement (this “License Agreement”) is entered into as of the           
day of May, 2008, by and between South Carolina Electric & Gas Company
(“SCE&G”), for itself and as agent for the South Carolina Public Service
Authority, a body corporate and politic created by the laws of South Carolina (“Santee
Cooper”) pursuant to the Limited Agency Agreement between SCE&G and Santee
Cooper dated                     ,
2008; and a consortium consisting of WESTINGHOUSE ELECTRIC COMPANY LLC, a
Delaware limited liability company having a place of business in Monroeville,
Pennsylvania (“Westinghouse”), and STONE & WEBSTER, INC., a Louisiana
corporation having a place of business in Charlotte, North Carolina (“Stone &
Webster”). Except where the context otherwise requires, Westinghouse and Stone &
Webster hereinafter are individually referred to as a “Consortium Member” and
collectively as “Contractor”.

 

1.                                       Definitions. For purposes of this software license (this “License Agreement”),
the terms listed below shall have the meanings indicated beside them.
Capitalized terms not otherwise defined below shall have the meanings ascribed
to them in the Agreement (as defined below).

 

(a)                                  “Agreement”
shall mean that certain Engineering, Procurement and Construction Agreement,
dated the date hereof, between South Carolina Electric & Gas Company,
for itself and as Agent for the South Carolina Public Service Authority, as
Owner, and Consortium Consisting of Westinghouse Electric Company LLC and Stone &
Webster, Inc., as Contractor for AP1000 Nuclear Power Plants.

 

(b)                                 “Available
Software” shall mean Software developed by or on behalf of a Consortium Member
(excluding software to be delivered under a separate nuclear fuel contract)
that, as of the date in question, either has been provided to Owner or is
complete and ready for delivery, provided, however, it is understood that
Available Software does not include Third-Party Software.

 

(c)                                  “Configuration Data” shall mean the
Unit-specific data that is used in conjunction with the Software, including
without limitation, tuning and set point constants, graphical, pictorial and
text files, that configure the Software for the specific Unit environment.

 

(d)                                 “Disabling
Code”  shall mean any timer, clock, counter, time
lock, time bomb, other limiting code, design, instruction or routine which is
designed or intended to do any of the following either automatically or without
the intentional action of a Permitted User: (i) erase data or other
programming, or (ii) damage, destroy, disable, suspend the operation of,
or alter the operation of the Software, or any components thereof, or (iii) cause
the Software or any components thereof to become inoperable or otherwise
incapable of being used in the full manner for which the Software is licensed
hereunder.

 

(e)                                  [**]

 

(f)                                    [**]

 

(g)                                 “Facility”
or “Unit” shall refer to the Facility or a Unit of the Facility as defined in
the Agreement.

 

“[**]” in this Exhibit
10.01 indicates material that has been omitted pursuant to a request for
confidential treatment and filed separately with the Securities and Exchange
Commission.

 

-1-

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

(h)                                 “Hardware”
shall mean (i) the hardware on which the Software is initially installed
by Contractor or Subcontractors for use in connection with the Facility,
including, without limitation, hardware at the Facility, redundant systems,
training and test systems and simulators associated with the Facility whether
located at the Facility or another site owned or leased by Owner or over which
Owner otherwise has possession or control and (ii) replacements and
additional hardware as permitted under Section 2(a)(iii).

 

(i)                                     “Permitted
Use” shall mean use solely in connection with the Facility, [**], and compliance with Laws or
Government Authorities.

 

(j)                                     “Permitted Users” shall mean Owner, its
employees, [**] secunded employees, and staff augmentation contractors through
multiple tiers, and their respective employees, which employees or contractors
have executed a written confidentiality agreement substantially as set forth in
Exhibit O-1 of the Agreement (Proprietary Data Agreement) or are otherwise
under an obligation or duty to Owner or to the contractor to maintain the
confidentiality of Owner’s or Owner’s suppliers’ proprietary information.

 

(k)                                  “Software” shall mean the computer
programs, procedures, rules or routines embodied in computer programs,
databases and related computer files provided to Owner by one or more of the
Consortium Members or Subcontractors in performance of the Work, as furnished
and as installed, and Application Software developed by one or more of the
Consortium Members for Owner during the performance of this License
Agreement.  Software shall also mean bug
fixes, error-correct releases, updates, upgrades, enhancements, modifications,
changes, new versions and replacements thereof if provided from time to time by
or on behalf of one or more of the Consortium Members or Subcontractors.  Software includes:

 

(i)                         “Base
Software”, which consists of [**]

 

(ii)                      “Application
Software”, which consists of all of the Software other than
Base Software and Third-Party Software, [**]. 
The Application Software is specific to a particular Unit.

 

“[**]” in this Exhibit
10.01 indicates material that has been omitted pursuant to a request for
confidential treatment and filed separately with the Securities and Exchange
Commission.

 

-2-

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

(iii)                   “Third-Party
Software”,  which
consists of  that portion of
the Software which is developed and owned by a third party (“Third Party”).

 

Except for purposes of
Subsections 4(b), (c) and (d), the term Software shall include all
software in the possession or control of any Consortium Member that would fall
within the definition of Software under this Subsection 1(k) above and be
Available Software, except for the fact that it has not yet been provided to
Owner or furnished, installed or completely developed; [**].

 

(l)                                     “Software Documentation” shall mean any
materials created by or on behalf of Contractor or its licensors, or by Third
Parties, that describe or relate to the functional, operational, or performance
capabilities of the Software regardless of whether such materials be in written,
printed, electronic or other format, and all of which shall be consistent, in
both form and substance, with Consortium Member’s quality management system
standards, industry standard for software documentation and be generally
acceptable to Contractor’s North American customers.

 

2.                                       Licenses.

 

(a)                                  Software
License. Each Consortium Member hereby grants to Permitted Users [**] right
and license to use the Software on the Hardware for Permitted Use.  [**] 
Without limiting the foregoing, the license granted herein shall include
the specific rights to:

 

(i)                                     [**]

 

(ii)                                  [**]

 

“[**]” in this Exhibit
10.01 indicates material that has been omitted pursuant to a request for
confidential treatment and filed separately with the Securities and Exchange
Commission.

 

-3-

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

[**]

 

(iii)                               [**]

 

(b)                                 Software
License Restrictions. Except as may be otherwise provided herein or in a
subsequent written agreement with the applicable Consortium Member or with an
owner or licensor of any Third-Party Software:

 

(i)                                     [**]

 

“[**]” in this Exhibit
10.01 indicates material that has been omitted pursuant to a request for
confidential treatment and filed separately with the Securities and Exchange
Commission.

 

-4-

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

(ii)                                  [**]

 

(c)                                  Software
Documentation Use and Restrictions. Contractor hereby grants to Owner [**]
right and license to reproduce and distribute to Permitted Users Software
Documentation for Permitted Use.   For
Third-Party Software license agreements not previously executed prior to the
date of the Agreement, the applicable Consortium Member agrees [**].

 

(d)                                 [**]

 

(e)                                  Other
Computer Programs. Nothing in the Agreement shall prohibit Owner from using
the Equipment to run computer programs other than the Software or from using
the Equipment for purposes other than operation of the Facility, it being
understood that Contractor shall not be responsible for any failure of the
Software or Equipment as a result of such activities, or from loading such
computer programs on, or removing such computer programs from, the Facility.

 

3.                                       Delivery, Installation and Acceptance of the Software.
The applicable Consortium Member shall deliver, install and test the Software
and Configuration Data, and Owner shall accept the Software and Configuration
Data, in accordance with the Project Schedule.

 

4.                                       Representations and Warranties. Contractor
represents and warrants the following:

 

(a)                                  Licensing Rights. The applicable
Consortium Member owns [**]

 

“[**]” in this Exhibit
10.01 indicates material that has been omitted pursuant to a request for
confidential treatment and filed separately with the Securities and Exchange
Commission.

 

-5-

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

[**]

 

(b)                                 Software Performance. For the
Equipment Warranty time period specified in section 14.1(a)(ii) of the
Agreement, after the Substantial Completion of each Unit (the “Software Warranty Period”)  the Software
and Configuration Data for that Unit shall: [**]

 

(c)                                  Media. The media on which the
Software, Configuration Data and Software Documentation are recorded shall be
free from defects in material and workmanship for the Software Warranty Period
set forth in (b) above. [**]

 

(d)                                 [**]

 

“[**]” in this Exhibit
10.01 indicates material that has been omitted pursuant to a request for
confidential treatment and filed separately with the Securities and Exchange
Commission.

 

-6-

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

[**]

 

5.                                       Intellectual Property Indemnity. (a) 
[**]

 

(b)                                 [**]

 

(c)                                  [**]

 

“[**]” in this Exhibit
10.01 indicates material that has been omitted pursuant to a request for
confidential treatment and filed separately with the Securities and Exchange
Commission.

 

-7-

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

[**]

 

6.                                       Proprietary Rights.

 

(a)                                  Except
for the licenses granted herein, [**]

 

(b)                                 All
rights, title and interests in and to [**]

 

(c)                                  All
rights, title and interests in and to any Application Software developed by
Contractor or at Contractor’s written instruction for Owner during the
performance of the Agreement [**].

 

(d)                                 To
the extent there are any conflicts between any of the provisions of this Article 6
of Exhibit M-1 and Article 19 of the Agreement, the provisions
of this Article 6 shall take precedence.

 

7.                                       [**].  (a) [**]

 

(b)                                 [**]

 

(c)                                  [**]

 

“[**]” in this Exhibit
10.01 indicates material that has been omitted pursuant to a request for
confidential treatment and filed separately with the Securities and Exchange
Commission.

 

-8-

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

[**]

 

(d)                                 [**]

 

8.                                       Bankruptcy Section 365(n). Contractor acknowledges and agrees that this
Software License creates no presumption that Contractor or any trustee or other
fiduciary of Contractor entitled to reject or terminate this Software License
under applicable Law.  Contractor
acknowledges that if Contractor as a debtor in possession or a trustee in
Bankruptcy (“Bankruptcy Trustee”)
in a case under the United States Bankruptcy Code rejects this Software
License, Owner may elect to retain its rights under this Software License as
provided in Section 365(n) of the United States Bankruptcy Code.  Upon written request of Owner to Contractor
or the Bankruptcy Trustee, Contractor or such Bankruptcy Trustee shall not
interfere with the rights of Owner as provided in this Software License,
including without limitation, the right to use or make available the Software
and Documentation.

 

9.                                       Assignment.  Neither
Party will be entitled (in whole or in part) to assign this License Agreement
or its rights hereunder or to delegate or subcontract its obligations hereunder
without the express written consent of the other Party hereto; provided,
however, that Owner shall have the right without the consent of Contractor or
any third party to assign, any and all of its rights under this Software
License to any party in connection with any transfer of ownership or control of
the Facility. Notwithstanding the above, assignments rights for Third-Party
Software shall be subject to the terms of the associated Third-Party Software
license.  Any assignment or transfer in
violation of this License Agreement will be null and void.  This License Agreement and the rights and
obligations of either Party hereto will be binding upon and will inure to the
benefit of the Parties hereto and their respective successors and permitted
assigns.

 

“[**]” in this Exhibit
10.01 indicates material that has been omitted pursuant to a request for
confidential treatment and filed separately with the Securities and Exchange
Commission.

 

-9-

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

IN WITNESS WHEREOF, the
Parties have duly executed this License Agreement as of the date first above
written.

 

	
  SOUTH CAROLINA
  ELECTRIC & GAS COMPANY,

  for itself and as agent for South Carolina Public Service

  Authority

  	
   

  
	
  By:

  	
   

  	
   

  	
   

  
	
  Name:

  	
   

  	
   

  	
   

  
	
  Title:

  	
   

  	
   

  	
   

  
	
   

  	
   

  
	
   

  	
   

  
	
  STONE &
  WEBSTER, INC.

  	
  WESTINGHOUSE ELECTRIC
  COMPANY LLC

  
	
   

  	
   

  
	
   

  	
   

  
	
  By:

  	
   

  	
   

  	
  By:

  	
   

  
	
  Name:

  	
   

  	
   

  	
  Name:

  	
   

  
	
  Title:

  	
   

  	
   

  	
  Title:

  	
   

  

 

“[**]” in this Exhibit
10.01 indicates material that has been omitted pursuant to a request for
confidential treatment and filed separately with the Securities and Exchange
Commission.

 

-10-

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

EXHIBIT M-2

AP1000 Intellectual Property License (WEC)

 

This
intellectual property license agreement (this “License Agreement”) is entered
into as of the            day
of May, 2008, by and between South Carolina Electric & Gas Company (“SCE&G”),
for itself and as agent for the South Carolina Public Service Authority, a body
corporate and politic created by the laws of South Carolina (“Santee Cooper”)
pursuant to the Limited Agency Agreement between SCE&G and Santee Cooper
dated                     ,
2008, and WESTINGHOUSE ELECTRIC COMPANY LLC, a Delaware limited liability
company having a place of business in Monroeville, Pennsylvania (“Westinghouse”).

 

1.                                       Definitions. For purposes of this License Agreement, the
terms listed below shall have the meanings indicated beside them. Capitalized
terms not otherwise defined below shall have the meanings ascribed to them in
the Engineering, Procurement and Construction Agreement between South Carolina
Electric & Gas Company, for itself and as agent for the South Carolina
Public Service Authority, and a consortium consisting of Westinghouse and Stone &
Webster, Inc., dated as of the date hereof (the “Agreement”). Except where
the context otherwise requires, Westinghouse and Stone & Webster, Inc.
hereinafter are individually referred to as a “Consortium Member” and
collectively as “Contractor”.

 

(a)                                  “Facility” or “Unit” shall refer to the
Facility or a Unit of the Facility as defined in the Agreement.

 

(b)                                 “Intellectual Property Rights” shall mean any
and all intellectual or industrial property rights owned by Westinghouse, or
which Westinghouse has the rights to transfer, sublicense or pass through,
related to the Facility Documentation necessary for a Qualified Entity to
utilize the Facility Documentation for Unit Completion Purposes, including,
without limitation, [**]  Intellectual
Property Rights shall not include the right to: (i) sue for infringement
or (ii) sublicense or sell except as expressly permitted in this License
Agreement, including, without limitation, under Sections 2(c) and 8, or (iii) reproduce
Facility Documentation that is subject to licensing restrictions.

 

(c)                                  “Qualified
Entity” shall mean a contractor, supplier or other entity that has ,as
recognized in the nuclear industry, 
the  capability and experience to
design and construct a nuclear power plant and that has entered into a confidentiality agreement that complies with
the applicable requirements under Section 2 (c).

 

(d)                                 “M-2 Triggering Event” shall mean the
occurrence of one or more of the events described under Section 22.2(a) and
the subsequent termination of the Agreement.

 

(e)                                  “Unit Completion Purposes” means solely for
purposes of Facility (and associated simulator) including, without limitation,
[**]

 

“[**]” in this
Exhibit 10.01 indicates material that has been omitted pursuant to a request
for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

-1-

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

[**]

 

2.                                       Licenses.

 

(a)                                  Intellectual Property License. [**]

 

(b)                                 Third Party Facility Documentation. 
Facility Documentation licensed by Westinghouse from Subcontractors or
third parties shall be licensed on a pass-through or sublicensing basis.  Such transactions may be subject to the
separate contractual or license agreements and limitations on copying and use,
and Owner agrees to and shall be bound by the terms of any such third-party
contractual or license agreements.

 

(c)                                  Sublicense Rights. 
Owner may sublicense the Facility Documentation and the Intellectual
Property Rights therein to one or more Qualified Entities solely for Unit
Completion Purposes; provided, however, that Owner agrees not to
grant any such sublicense unless at some time after the issuance of a Full
Notice to Proceed but prior to achieving Substantial Completion, a M-2
Triggering Event occurs, and provided  further, however,
that prior to entering into each such sublicense and prior to disclosure of
Facility Documentation to any Qualified Entity, Owner shall notify Westinghouse
of the identity of the Qualified Entity and the Qualified Entity shall enter into
a confidentiality agreement largely in conformance with the Proprietary Data
Agreement set forth in Exhibit O-1 to the Agreement.   Any sublicense shall be in writing and shall
identify Westinghouse as the owner or licensee of the Facility Documentation,
as applicable. A fully executed copy of such sublicense shall be provided to
Westinghouse.   Owner agrees that neither
it nor any of its employees, agents and/or others over which it has control
shall disclose any Facility Documentation to any third party, except as may be
otherwise expressly allowed by this License Agreement or provided in the
Agreement or applicable confidentiality or non-disclosure agreement.

 

(d)                                 Improvements. Westinghouse, to the extent required for
Owner to make changes, modifications, enhancements and improvements, grants
Owner the right to make changes, modifications, enhancements, and improvements
to the Facility Documentation and the Intellectual Property Rights therein, and
to create derivative works of the foregoing (collectively referred to as “Improvements”),
and to use such Improvements solely for Unit Completion Purposes.  [**]

 

“[**]” in this
Exhibit 10.01 indicates material that has been omitted pursuant to a request
for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

-2-

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

[**]  For the avoidance of doubt, this paragraph is
not intended to assign or transfer ownership or otherwise give up any right in
and to the Facility Documentation or the Intellectual Property Rights therein
that may be incorporated into or used in conjunction with the Improvements or
to permit Owner or any other Third Party to use Facility Documentation except
as provided for in this License Agreement.

 

(e)                                  Documentation.  Upon
Owner’s request at any time after the occurrence of an M-2 Triggering Event,
Westinghouse shall provide to Owner, at reasonable copying and delivery cost to
Owner [**]  Upon Westinghouse’s written
request and the execution of the right and license contemplated under (d) above,
Owner agrees to provide Westinghouse a copy of any manuals and like materials
created and used by Owner with respect to the Improvements and any know how
related to the Improvements.

 

3.                                       Representations and
Warranties. Westinghouse
represents and warrants that Westinghouse owns all rights, title and interest
(or otherwise has the necessary rights to transfer and/or grant the rights
provided for herein) in the Facility Documentation and the Intellectual
Property Rights therein that are in existence on the date hereof [**]

 

4.                                       Intellectual
Property Indemnity.  (a)  [**]

 

“[**]” in this
Exhibit 10.01 indicates material that has been omitted pursuant to a request
for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

-3-

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

[**]

 

(b)                                 Westinghouse shall not compromise or settle
any claim, action, suit or proceeding in which an Owner is named without Owner’s
prior written consent, which consent shall not be unreasonably conditioned,
delayed or withheld, unless such settlement provides for the payment of money
only by Westinghouse and provides for a full, complete and unconditional
release of Owner and each Qualified Entity.

 

(c)                                  [**]

 

(d)                                 Owner hereby releases and agrees to defend
and indemnify Westinghouse and its Subcontractors from and against any and all
third party (“third party” not to include any Subcontractor, Consortium Member
or other third party to whose Facility Documentation and Intellectual Property
Rights therein Owner is granted a license and right under Section 2(a))
claims, demands, costs, suits, actions, proceedings, fines and penalties (and
interest thereon) brought against Westinghouse or its Subcontractors that (i) any
Improvement as used by Owner or any Qualified Entity, or (ii) any use by
Owner or any Qualified Entity of the Facility Documentation in a manner not
contemplated by this License Agreement, results in an infringement, or claim of
infringement, of any patent, trademark, copyright or other third party
intellectual property right, or any other similar intellectual property
protection enforceable in the United States, Canada, or a European Union
country, if Owner is notified promptly in writing and given authority,
information, and assistance for the defense of any such suit or proceeding.

 

EXCEPT
AS PROVIDED ABOVE, WESTINGHOUSE MAKES NO WARRANTIES AND OWNER HEREBY WAIVES ANY
CLAIM FOR LIABILITY AND ANY EXPRESS OR IMPLIED WARRANTY OF ANY KIND RELATED TO
THE FACILITY DOCUMENTATION OR THIS INTELLECTUAL PROPERTY LICENSE, INCLUDING,
WITHOUT LIMITATION, THE IMPLIED WARRANTY OF FITNESS FOR A PARTICULAR PURPOSE OR
MERCHANTABILITY OR NON-INFRINGEMENT.

 

“[**]” in this
Exhibit 10.01 indicates material that has been omitted pursuant to a request
for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

-4-

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

OWNER
MAKES NO WARRANTIES AND WESTINGHOUSE HEREBY WAIVES ANY CLAIM FOR LIABILITY AND
ANY EXPRESS OR IMPLIED WARRANTY OF ANY KIND RELATED TO ANY AND ALL
IMPROVEMENTS, INCLUDING, WITHOUT LIMITATION, THE IMPLIED WARRANTY OF FITNESS
FOR A PARTICULAR PURPOSE OR MERCHANTABILITY OR NON-INFRINGEMENT.

 

THIS
IS AN EXCLUSIVE STATEMENT RELATING TO FACILITY DOCUMENTATION AND THE
INTELLECTUAL PROPERTY RIGHTS THEREIN AND IMPROVEMENTS RIGHTS PURSUANT TO THIS
LICENSE AGREEMENT AND ALL THE REMEDIES OF THE PARTIES RELATING THERETO.

 

5.                                       Proprietary Rights.  (a)                        Except for the licenses granted herein, all
rights, title and interests in and to the Facility Documentation and
Intellectual Property Rights therein shall remain exclusively with Westinghouse
or it licensors.

 

(b)                                 All rights title and interests in and to any
new material subject to patent, trade secret, or copyright protection added to
the Facility Documentation or the Intellectual Property Rights therein by or on
behalf of the Owner [**] right and license to use such new material added to
the Facility Documentation solely in support of the Facility.

 

(c)                                  To the extent there are any conflicts between
any of the provisions of this License Agreement and Article 19 of the
Agreement, the provisions of this License Agreement shall control.

 

6.                                       [**]

 

“[**]” in this
Exhibit 10.01 indicates material that has been omitted pursuant to a request
for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

-5-

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

7.                                       Bankruptcy Section 365(n). Westinghouse acknowledges and agrees that
this License Agreement creates no presumption that Westinghouse or any trustee
or other fiduciary of Westinghouse is entitled to reject or terminate the Agreement
or this License Agreement under applicable Law. 
Westinghouse acknowledges that if Westinghouse as a debtor in possession
or a trustee in Bankruptcy (“Bankruptcy
Trustee”) in a case under the United States Bankruptcy Code rejects the
Agreement or this License Agreement, Owner may elect to retain its rights under
this License Agreement as provided in Section 365(n) of the United
States Bankruptcy Code.  Upon written
request of Owner to Westinghouse or the Bankruptcy Trustee, Westinghouse or
such Bankruptcy Trustee shall not interfere with the rights of Owner as
provided in this License Agreement, including without limitation, the right to
use or make available the Facility Documentation and the Intellectual Property
Rights therein.

 

8.                                       Assignment.  Neither
Party will be entitled (in whole or in part) to assign this License Agreement
or its rights hereunder or to delegate or subcontract its obligations hereunder
without the express written consent of the other Party hereto; provided,
however, that Owner shall have the right without the consent of Westinghouse or
any third party to assign or otherwise transfer any and all of its rights under
this License Agreement to any party in connection with any assignment, sale or
transfer of the Facility or any Unit or of control of the Facility or a Unit.
Assignment of Third Party Intellectual Property shall be governed by the terms
of the applicable Third Party license. 
Any assignment or transfer in violation of this License Agreement will
be null and void.  This License Agreement
and the rights and obligations of either Party hereto will be binding upon and
will inure to the benefit of the Parties hereto and their respective successors
and permitted assigns.

 

9.                                       Subsequent to Substantial Completion. 
Notwithstanding any other provision of this License Agreement, this
License Agreement shall terminate upon the equivalent of [**] and at all times
subsequent to the equivalent of [**] all Facility Documentation and
Intellectual Property Rights therein provided or otherwise made available to
Owner under this License Agreement, shall, subject to the exceptions contained
in the definition of the term Proprietary Data, be deemed Proprietary Data
(unless otherwise denoted in writing as agreed to by the parties) and Owner shall
have the rights and obligations with respect thereto as set forth in Article 19
of the Agreement.

 

“[**]” in this
Exhibit 10.01 indicates material that has been omitted pursuant to a request
for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

-6-

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

IN WITNESS WHEREOF, the Parties have duly executed this License
Agreement as of the date first above written.

 

 

	
  SOUTH
  CAROLINA ELECTRIC & GAS COMPANY,

  for itself and as agent for South Carolina Public Service

  Authority

  	
   

  
	
   

  	
   

  
	
   

  	
   

  
	
  By:

  	
   

  	
   

  
	
  Name:

  	
   

  	
   

  
	
  Title:

  	
   

  	
   

  
	
   

  	
   

  
	
   

  	
   

  
	
  WESTINGHOUSE
  ELECTRIC COMPANY LLC

  	
   

  
	
   

  	
   

  
	
   

  	
   

  
	
  By:

  	
   

  	
   

  
	
  Name:

  	
   

  	
   

  
	
  Title:

  	
   

  	
   

  

 

“[**]” in this
Exhibit 10.01 indicates material that has been omitted pursuant to a request
for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

-7-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT M-3

AP1000 Intellectual Property License (S&W)

 

This intellectual property agreement (this “License
Agreement”) is entered into as of the           
day of May, 2008, by and between South Carolina Electric & Gas Company (“SCE&G”),
for itself and as agent for the South Carolina Public Service Authority, a body
corporate and politic created by the laws of South Carolina (“Santee Cooper”)
pursuant to the Limited Agency Agreement between SCE&G and Santee Cooper
dated                     ,
2008, and STONE & WEBSTER, INC., a Louisiana corporation having a place of
business in Charlotte, North Carolina (“Stone & Webster”).

 

1.             Definitions. For purposes of this License Agreement, the terms listed below
shall have the meanings indicated beside them. Capitalized terms not otherwise
defined below shall have the meanings ascribed to them in the Engineering,
Procurement and Construction Agreement between South Carolina Electric &
Gas Company, for itself and as agent for the South Carolina Public Service
Authority, and a consortium consisting of Westinghouse Electric Company LLC and
Stone & Webster, dated as of the date hereof (the “Agreement”). Except
where the context otherwise requires, Westinghouse Electric Company LLC and
Stone & Webster hereinafter are individually referred to as a “Consortium
Member” and collectively as “Contractor”.

 

(a)           “Facility” or “Unit” shall refer to
the Facility or a Unit of the Facility as defined in the Agreement.

 

(b)           “Intellectual Property Rights” shall
mean any and all intellectual or industrial property rights owned by Stone &
Webster, or which Stone & Webster has the rights to transfer, sublicense or
pass through, related to the Facility Documentation necessary for a Qualified
Entity to utilize the Facility Documentation for Unit Completion Purposes,
including, without limitation, [**] 
Intellectual Property Rights shall not include the right to: (i) sue for
infringement or (ii) sublicense or sell except as expressly permitted in this
License Agreement, including, without limitation, under Sections 2(c) and 8, or
(iii) reproduce Facility Documentation that is subject to licensing
restrictions.

 

(c)          “Qualified Entity” shall mean a
contractor, supplier or other entity that has ,as recognized in the nuclear
industry, the capability and experience to design and construct a nuclear power
plant and that has entered into
a confidentiality agreement that complies with the applicable requirements under
Section 2 (c).

 

(d)           “M-3 Triggering Event” shall mean the
occurrence of one or more of the events described under Section 22.2(a) and the
subsequent termination of the Agreement.

 

(e)           “Unit Completion Purposes” means
solely for purposes of Facility (and associated simulator) including, without
limitation, [**]

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

-1-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

[**]

 

2.            Licenses.

 

(a)           Intellectual Property License.
[**]

 

(b)           Third Party Facility Documentation.  Facility Documentation licensed by Stone &
Webster from Subcontractors or third parties shall be licensed on a
pass-through or sublicensing basis.  Such
transactions may be subject to the separate contractual or license agreements
and limitations on copying and use, and Owner agrees to and shall be bound by
the terms of any such third-party contractual or license agreements.

 

(c)           Sublicense Rights.  Owner may sublicense the Facility
Documentation and the Intellectual Property Rights therein to one or more
Qualified Entities solely for Unit Completion Purposes; provided, however,
that Owner agrees not to grant any such sublicense unless at some time after
the issuance of a Full Notice to Proceed but prior to achieving Substantial
Completion, a M-3 Triggering Event occurs, and provided  further, however,
that prior to entering into each such sublicense and prior to disclosure of
Facility Documentation to any Qualified Entity, Owner shall notify Stone &
Webster of the identity of the Qualified Entity and the Qualified Entity shall
enter into a confidentiality agreement largely in conformance with the
Proprietary Data Agreement set forth in Exhibit O-1 to the
Agreement.  Any sublicense shall be in
writing and shall identify Stone & Webster as the owner or licensee of the
Facility Documentation, as applicable. A fully executed copy of such sublicense
shall be provided to Stone & Webster. 
Owner agrees that neither it nor any of its employees, agents and/or
others over which it has control shall disclose any Facility Documentation to
any third party, except as may be otherwise expressly allowed by this License
Agreement or provided in the Agreement or applicable confidentiality or
non-disclosure agreement.

 

(d)           Improvements. Stone &
Webster, to the extent required for Owner to make changes, modifications,
enhancements and improvements, grants Owner the right to make changes,
modifications, enhancements, and improvements to the Facility Documentation and
the Intellectual Property Rights therein, and to create derivative works of the
foregoing (collectively referred to as “Improvements”), and to use such
Improvements solely for Unit Completion Purposes.  [**]

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

-2-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

[**] 
For the avoidance of doubt, this paragraph is not intended to assign or
transfer ownership or otherwise give up any right in and to the Facility
Documentation or the Intellectual Property Rights therein that may be
incorporated into or used in conjunction with the Improvements or to permit
Owner or any other Third Party to use Facility Documentation except as provided
for in this License Agreement.

 

(e)           Documentation.  Upon Owner’s request at any time after the
occurrence of an M-3 Triggering Event, Stone & Webster shall provide to
Owner, at reasonable copying and delivery cost to Owner [**].  Upon Stone & Webster’s written request
and the execution of the right and license contemplated under (d) above, Owner
agrees to provide Stone & Webster a copy of any manuals and like materials
created and used by Owner with respect to the Improvements and any know how
related to the Improvements.

 

3.             Representations and Warranties.
Stone & Webster represents and warrants that Stone & Webster owns all
rights, title and interest (or otherwise has the necessary rights to transfer
and/or grant the rights provided for herein) in the Facility Documentation and
the Intellectual Property Rights therein that are in existence on the date
hereof [**].

 

4.             Intellectual Property Indemnity. 
(a)  [**]

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

-3-

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject
  to Restricted Procedures

  

 

[**]

 

(b)           Stone
& Webster shall not compromise or settle any claim, action, suit or
proceeding in which an Owner is named without Owner’s prior written consent,
which consent shall not be unreasonably conditioned, delayed or withheld,
unless such settlement provides for the payment of money only by Stone &
Webster and provides for a full, complete and unconditional release of Owner
and each Qualified Entity.

 

(c)           [**]

 

(d)           Owner hereby releases and agrees to
defend and indemnify Stone & Webster and its Subcontractors from and
against any and all third party (“third party” not to include any
Subcontractor, Consortium Member or other third party to whose Facility
Documentation and Intellectual Property Rights therein Owner is granted a
license and right under Section 2(a)) claims, demands, costs, suits, actions,
proceedings, fines and penalties (and interest thereon) brought against Stone &
Webster or its Subcontractors that (i) any Improvement as used by Owner or any
Qualified Entity, or (ii) any use by Owner or any Qualified Entity of the
Facility Documentation in a manner not contemplated by this License Agreement,
results in an infringement, or claim of infringement, of any patent, trademark,
copyright or other third party intellectual property right, or any other
similar intellectual property protection enforceable in the United States,
Canada, or a European Union country, if Owner is notified promptly in writing
and given authority, information, and assistance for the defense of any such
suit or proceeding.

 

EXCEPT AS PROVIDED ABOVE, STONE & WEBSTER
MAKES NO WARRANTIES AND OWNER HEREBY WAIVES ANY CLAIM FOR LIABILITY AND ANY
EXPRESS OR IMPLIED WARRANTY OF ANY KIND RELATED TO THE FACILITY DOCUMENTATION
OR THIS INTELLECTUAL PROPERTY LICENSE, INCLUDING, WITHOUT LIMITATION, THE
IMPLIED WARRANTY OF FITNESS FOR A PARTICULAR PURPOSE OR MERCHANTABILITY OR
NON-INFRINGEMENT.

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

-4-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

OWNER MAKES NO WARRANTIES AND STONE &
WEBSTER HEREBY WAIVES ANY CLAIM FOR LIABILITY AND ANY EXPRESS OR IMPLIED
WARRANTY OF ANY KIND RELATED TO ANY AND ALL IMPROVEMENTS, INCLUDING, WITHOUT
LIMITATION, THE IMPLIED WARRANTY OF FITNESS FOR A PARTICULAR PURPOSE OR
MERCHANTABILITY OR NON-INFRINGEMENT.

 

THIS IS AN EXCLUSIVE STATEMENT RELATING TO
FACILITY DOCUMENTATION AND THE INTELLECTUAL PROPERTY RIGHTS THEREIN AND
IMPROVEMENTS RIGHTS PURSUANT TO THIS LICENSE AGREEMENT AND ALL THE REMEDIES OF
THE PARTIES RELATING THERETO.

 

5.            Proprietary
Rights.  (a)         Except for the licenses granted herein,
all rights, title and interests in and to the Facility Documentation and
Intellectual Property Rights therein shall remain exclusively with Stone &
Webster or it licensors.

 

(b)           All rights title and interests in and
to any new material subject to patent, trade secret, or copyright protection
added to the Facility Documentation or the Intellectual Property Rights therein
by or on behalf of the Owner [**].  Owner
hereby grants Contractor a [**] right and license to use such new material
added to the Facility Documentation solely in support of the Facility.

 

(c)           To the extent there are any conflicts
between any of the provisions of this License Agreement and Article 19 of the
Agreement, the provisions of this License Agreement shall control.

 

6.            [**]

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

-5-

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

7.             Bankruptcy
Section 365(n). Stone
& Webster acknowledges and agrees that this License Agreement creates no
presumption that Stone & Webster or any trustee or other fiduciary of Stone
& Webster is entitled to reject or terminate the Agreement or this License
Agreement under applicable Law.  Stone &
Webster acknowledges that if Stone & Webster as a debtor in possession or a
trustee in Bankruptcy (“Bankruptcy
Trustee”) in a case under the United States Bankruptcy Code rejects the
Agreement or this License Agreement, Owner may elect to retain its rights under
this License Agreement as provided in Section 365(n) of the United States
Bankruptcy Code.  Upon written request of
Owner to Stone & Webster or the Bankruptcy Trustee, Stone & Webster or
such Bankruptcy Trustee shall not interfere with the rights of Owner as
provided in this License Agreement, including without limitation, the right to
use or make available the Facility Documentation and the Intellectual Property
Rights therein.

 

8.             Assignment.  Neither Party will be entitled (in whole or in
part) to assign this License Agreement or its rights hereunder or to delegate
or subcontract its obligations hereunder without the express written consent of
the other Party hereto; provided, however, that Owner shall have the right
without the consent of Stone & Webster or any third party to assign or
otherwise transfer any and all of its rights under this License Agreement to
any party in connection with any assignment, sale or transfer of the Facility
or any Unit or of control of the Facility or a Unit. Assignment of Third Party
Intellectual Property shall be governed by the terms of the applicable Third
Party license.  Any assignment or
transfer in violation of this License Agreement will be null and void.  This License Agreement and the rights and
obligations of either Party hereto will be binding upon and will inure to the
benefit of the Parties hereto and their respective successors and permitted
assigns.

 

9.             Subsequent
to Substantial Completion. 
Notwithstanding any other provision of this License Agreement, this
License Agreement shall terminate upon the equivalent of [**] and at all times
subsequent to the equivalent of [**] all Facility Documentation and
Intellectual Property Rights therein provided or otherwise made available to
Owner under this License Agreement, shall, subject to the exceptions contained
in the definition of the term Proprietary Data, be deemed Proprietary Data
(unless otherwise denoted in writing as agreed to by the parties) and Owner
shall have the rights and obligations with respect thereto as set forth in Article
19 of the Agreement.

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

-6-

 

	
  Execution Version

  	
  Confidential Trade Secret Information—Subject
  to Restricted Procedures

  

 

IN WITNESS
WHEREOF, the Parties
have duly executed this License Agreement as of the date first above written.

 

 

	
  SOUTH CAROLINA ELECTRIC &
  GAS COMPANY,

  for itself and as agent for South Carolina Public Service Authority

  	
   

  
	
   

  	
   

  
	
   

  	
   

  
	
  By:

  	
   

  	
   

  
	
  Name:

  	
   

  	
   

  
	
  Title:

  	
   

  	
   

  
	
   

  	
   

  
	
   

  	
   

  
	
  STONE & WEBSTER, INC.

  	
   

  
	
   

  	
   

  
	
   

  	
   

  
	
  By:

  	
   

  	
   

  
	
  Name:

  	
   

  	
   

  
	
  Title:

  	
   

  	
   

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

-7-

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

EXHIBIT N

Industry
Codes And Standards

 

Table of
Contents

 

	
  Introduction

  	
  3

  
	
  Codes and Standards

  	
   

  
	
  ACI - American Concrete
  Institute

  	
  5

  
	
  AISC - American
  Institute of Steel Construction

  	
  5

  
	
  AISI - American Iron
  and Steel Institute

  	
  5

  
	
  AMCA - Air Movement and
  Control Association, Inc.

  	
  5

  
	
  ANS – American Nuclear
  Society

  	
  6

  
	
  ANSI – American
  National Standards Institute

  	
  7

  
	
  API – American
  Petroleum Institute

  	
  9

  
	
  ARI – Air Conditioning
  and Refrigeration Institute

  	
  9

  
	
  ASCE – American Society
  of Civil Engineers

  	
  10

  
	
  ASHRAE – American
  Society of Heating, Refrigeration, and Air Conditioning Engineers

  	
  10

  
	
  ASME – American Society
  of Mechanical Engineers

  	
  10

  
	
  ASTM – American Society
  of Testing and Materials

  	
  14

  
	
  AWS – American Welding
  Society

  	
  15

  
	
  AWWA – American Water
  Works Association

  	
  15

  
	
  CMAA – Crane
  Manufacturers Association of America

  	
  15

  
	
  FEMA – Federal
  Emergency Management Agency

  	
  16

  
	
  IEEE – Institute of
  Electrical and Electronics Engineers

  	
  16

  
	
  ISA – Instrumentation,
  Systems and Automation Society

  	
  20

  
	
  MIL – Military
  Standards and Specifications

  	
  20

  
	
  NEMA – National
  Electrical Manufacturers Association

  	
  20

  
	
  NFPA – National Fire
  Protection Association

  	
  20

  
	
  SMACNA – Sheet Metal
  and Air Conditioning Contractors National Association

  	
  22

  
	
  UBC – Uniform Building
  Code

  	
  22

  
	
  UL – Underwriters
  Laboratories, Inc.

  	
  22

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

1 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

AP1000
Nuclear Power Plant Codes and Standards Introduction

 

This document provides
the listing of industry codes and standards that are applicable to the AP1000
Nuclear Power Plant design (the “Industry Codes and Standards”). The attached
listing of the Industry Codes and Standards is derived from the AP1000 Design
Certification Document (DCD). This list therefore is a listing of codes and
standards that the AP1000 Nuclear Power Plant design is committed to by the
licensing process. The revision or date of each code and standard is also
included in the attached table.  For
codes and standards that were provided in the DCD without revision or date, the
revision or date in effect, March 2002 (submittal date of the AP1000 Nuclear
Power Plant design to NRC) was used.  The
revisions reflect the DCD licensing commitment. Changes to the standard or
revision may require a licensing submittal by the Owner. Contractor will notify
Owner of any proposed changes to the listing of Industry Codes and Standards to
ensure that they are reflected in future licensing submittals.

 

Except as provided below,
regarding ASME application, the edition and addenda of the ASME code applied in
the design and manufacture of each component is the edition and addenda
established by the requirements of the DCD. The use of editions and addenda
issued subsequent to the DCD is permitted, however any change to ASME code
edition will require NRC approval. In the event the DCD does not specify the
edition and addenda of the code applicable to an activity required under the
Agreement, the activity will be performed in compliance with the code edition
and addenda required under 10 CFR 50.55a. The baseline used for the evaluations
done to support this Design Control Document and the DCD is the 1998 Edition,
2000 Addenda, except as follows:

 

The 1989 Edition, 1989
Addenda is used for Articles NB-3200 (Design by Analysis), NB-3600, NC-3600,
and ND-3600 (Piping Design) in lieu of later editions and addenda.

 

Guidance for ASME code
year and addenda to use in mechanical equipment and valve specifications:

 

CASE 1: ASME Section III
Safety Related Equipment in Support of the Design Certification

 

If the principal
construction code for the equipment is ASME Section III as defined in Table
3.2-3 of the DCD, then the year and addenda shall be in accordance with
paragraphs 5.2.1.1 and 6.1.1 of the DCD (i.e., 1998 year with 2000 addenda),
except as follows:

 

“The 1989 Edition, 1989
Addenda is used for Articles NB-3200 (Design by Analysis), NB-3600, NC-3600,
and ND-3600 (Piping Design) in lieu of later editions and addenda.”

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

2 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Any other ASME BP&V
Code Sections listed within the equipment specification for this equipment
(e.g., II, V, IX, and XI) shall have the same 1998 year and 2000 addenda.

 

In addition to AP1000
Nuclear Power Plant codes A, B, and C, the above applies to code D non-safety
equipment being built to ASME Section III as the principal construction code
defined in Table 3.2-3 of the DCD.

 

CASE 2: Non-ASME Section III
Equipment (Non-Safety Related Equipment)

 

If the equipment
principal construction code is ASME but NOT Section III as defined in Table
3.2-3 in the DCD (e.g., ASME Section VIII for pressure tanks/vessels), then the
ASME 2001 year and 2003 addenda shall be used, unless otherwise specified in
the DCD.  ASME Section III will NOT be
included in the specifications and standards list in the equipment
specification.

 

If any other ASME
Sections are listed within the equipment specification (e.g., ASME Section IX
for welding requirements), then the 2001 year with 2003 addenda shall be used
for them as well.

 

Additional codes and
standards may be applied to the final AP1000 Nuclear Power Plant design at the
sole discretion of Contractor. These additional codes and standards will then
be requirements for the AP1000 Nuclear Power Plant design, however they will
not be required by licensing and therefore the date and application is subject
to change as determined by Contractor in its sole discretion.

 

The attached table, Table
1, only list industry codes and standards. 
Regulatory standards (Regulatory Guides, NUREGs, etc.) are not included
in the attachment; these standards are referenced in the DCD.

 

Table 2 identifies codes
and standards that are not included in the Licensing Basis but are pertinent to
the Facility.  Since they are not
included as part of the Licensing Basis, revisions may be used as determined by
Contractor in its sole discretion.

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

3 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Table 1

AP1000
Codes and Standards (Licensing Basis)

 

	
  Title

  	
   

  	
  DCD
  Section

  
	
   

  	
   

  	
   

  
	
  ACI - American Concrete
  Institute

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  ACI 117, “Standard
  Specification for Tolerances for Concrete Construction and Materials,” 1990

  	
   

  	
  3.8

  
	
   

  	
   

  	
   

  
	
  ACI 211.1, “Standard
  Practice for Selecting Proportions for Normal, Heavy Weight, and Mass
  Concrete,” 1991

  	
   

  	
  3.8

  
	
   

  	
   

  	
   

  
	
  ACI 304R, “Guide for
  Measuring, Mixing, Transporting, and Placing Concrete,” 2000

  	
   

  	
  3.8

  
	
   

  	
   

  	
   

  
	
  ACI 318, “Building Code
  Requirements for Reinforced Concrete,” 2002

  	
   

  	
  2.5

  
	
   

  	
   

  	
   

  
	
  ACI 349.3R, “Evaluation
  of Existing Nuclear Safety-Related Concrete Structures,” 1996

  	
   

  	
  3.8

  
	
   

  	
   

  	
   

  
	
  ACI 349, “Code
  Requirements for Nuclear Safety Related Concrete Structures,” 2001

  	
   

  	
  1A, 3.8, 3H

  
	
   

  	
   

  	
   

  
	
  AISC - American Institute of
  Steel Construction

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  AISC N690, “Specification
  for the Design, Fabrication, and Erection of Steel Safety-Related Structures
  for Nuclear Facilities,” 1994

  	
   

  	
  3A, 3F, 3H

  
	
   

  	
   

  	
   

  
	
  AISC S335,
  “Specification for Structural Steel Buildings, Allowable Stress Design and
  Plastic Design,” 1989

  	
   

  	
  3.3

  
	
   

  	
   

  	
   

  
	
  Seismic Provisions for
  Structural Steel Buildings, American Institute of Steel Construction, April 1977
  including Supplement 2, November 2000

  	
   

  	
  3.7

  
	
   

  	
   

  	
   

  
	
  AISI - American Iron and Steel
  Institute

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  AISI, “Specification
  for the Design of Cold Formed Steel Structural Members,” 1996 Edition and
  Supplement No. 1, July 30, 1999

  	
   

  	
  3A, 3F

  
	
   

  	
   

  	
   

  
	
  AMCA - Air Movement and Control
  Association, Inc.

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  AMCA 210, “Laboratory
  Method of Testing Fans for Rotating Purposes,” 1985

  	
   

  	
  9.4

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

4 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Table 1

AP1000
Codes and Standards (Licensing Basis)

 

	
  Title

  	
   

  	
  DCD
  Section

  
	
   

  	
   

  	
   

  
	
  AMCA 211, “Certified
  Ratings Program Air Performance,” 1987

  	
   

  	
  9.4

  
	
   

  	
   

  	
   

  
	
  AMCA 300, “Reverberant
  Room Method for Sound Testing of Fans,” 1985

  	
   

  	
  9.4

  
	
   

  	
   

  	
   

  
	
  AMCA 500, “Test Method
  for Louvers, Dampers, and Shutters,”1989

  	
   

  	
  9.4

  
	
   

  	
   

  	
   

  
	
  ANS – American Nuclear Society

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  ANS 5.1, “Decay Heat
  Power in Light Water Reactors,” 1994

  	
   

  	
  5.4

  
	
   

  	
   

  	
   

  
	
  ANS 5.1, “Decay Heat
  Power in Light Water Reactor,” 1979

  	
   

  	
  1.9, 15.2

  
	
   

  	
   

  	
   

  
	
  ANS 5.4, “American
  National Standard Method for Calculating the Fractional Release of Volatile
  Fission Products From Oxide Fuel,” 1982

  	
   

  	
  1A

  
	
   

  	
   

  	
   

  
	
  ANS 6.1, “Guidelines on
  the Nuclear Analysis and Design of Concrete Radiation Shielding for Nuclear
  Power Plants,” 1989

  	
   

  	
  12.3

  
	
   

  	
   

  	
   

  
	
  ANS 6.4, “Guidelines on
  the Nuclear Analysis and Design of Concrete Radiation Shielding for Nuclear
  Power Plants,” 1997

  	
   

  	
  1A, 12.3

  
	
   

  	
   

  	
   

  
	
  ANS 15.8, “Nuclear
  Material Control Systems for Nuclear Power Plants,” 1974

  	
   

  	
  13

  
	
   

  	
   

  	
   

  
	
  ANS 18.1, “Radioactive
  Source Term for Normal Operation of Light Water Reactors,” 1999

  	
   

  	
  1A, 11.1

  
	
   

  	
   

  	
   

  
	
  ANS 51.1, “Nuclear
  Safety Criteria for the Design of Stationary Pressurized Water Reactor
  Plants,” 1983

  	
   

  	
  3.2, 3.9, 5.4,
  9.3

  
	
   

  	
   

  	
   

  
	
  ANS 55.6, “Liquid
  Radioactive Waste Processing Systems for Light Water Reactor Plants,” 1993

  	
   

  	
  11.2

  
	
   

  	
   

  	
   

  
	
  ANS 56.2, “Containment
  Isolation Provisions for Fluid Systems,” 1984

  	
   

  	
  1A

  
	
   

  	
   

  	
   

  
	
  ANS 56.11, “Design
  Criteria for Protection Against the Effects of Compartment Flooding in Light
  Water Reactor Plants,” 1988

  	
   

  	
  3.4

  
	
   

  	
   

  	
   

  
	
  ANS 57.1, “Design
  Requirements for Light Water Reactor Fuel Handling Systems,” 1992

  	
   

  	
  9.1

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

5 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Table 1

AP1000
Codes and Standards (Licensing Basis)

 

	
  Title

  	
   

  	
  DCD
  Section

  
	
   

  	
   

  	
   

  
	
  ANS 57.2, “Design
  Requirements for Light Water Reactor Spent Fuel Storage Facilities at Nuclear
  Power Plants,” 1983

  	
   

  	
  4.3, 9.1

  
	
   

  	
   

  	
   

  
	
  ANS 57.3, “Design
  Requirements for New Fuel Storage Facilities at LWR Plants,” 1983

  	
   

  	
  4.3

  
	
   

  	
   

  	
   

  
	
  ANS 58.2, “Design Bases
  for Protection of Light Water Nuclear Power Plants Against Effects of
  Postulated Pipe Rupture,” 1988

  	
   

  	
  3.6

  
	
   

  	
   

  	
   

  
	
  ANS 58.8, “Time
  Response Design Criteria for Nuclear Safety Related Operator Actions,” 1984

  	
   

  	
  1.9

  
	
   

  	
   

  	
   

  
	
  ANS C-2, “National
  Electrical Safety Codes,” 1997

  	
   

  	
  8.2

  
	
   

  	
   

  	
   

  
	
  ANSI – American National
  Standards Institute

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  ANSI 16.1, “Nuclear
  Criticality Safety in Operations with Fissionable Materials Outside
  Reactors,” 1975

  	
   

  	
  9.1

  
	
   

  	
   

  	
   

  
	
  ANSI 56.5, “PWR and BWR
  Containment Spray System Design Criteria,” 1979

  	
   

  	
  1.9

  
	
   

  	
   

  	
   

  
	
  ANSI 56.8, “Containment
  System Leakage Testing Requirements,” 1994

  	
   

  	
  6.2

  
	
   

  	
   

  	
   

  
	
  ANSI 58.6, “Criteria
  for Remote Shutdown for Light Water Reactors,” 1996

  	
   

  	
  7.4

  
	
   

  	
   

  	
   

  
	
  ANSI B16.34, “Valves –
  Flanged and Buttwelding End,” 1996

  	
   

  	
  3.2

  
	
   

  	
   

  	
   

  
	
  ANSI B16.41,
  “Functional Operational Requirement for Power Operated Valves,” 1983

  	
   

  	
  1.9

  
	
   

  	
   

  	
   

  
	
  ANSI B30.2, “Overhead
  and Gantry Cranes,” 1990

  	
   

  	
  9.1

  
	
   

  	
   

  	
   

  
	
  ANSI B30.9, “Slings,”
  1996

  	
   

  	
  9.1

  
	
   

  	
   

  	
   

  
	
  ANSI B31.1, “Power
  Piping, ASME Code for Pressure Piping,” 1989

  	
   

  	
  3.2, 3.6, 9.2

  
	
   

  	
   

  	
   

  
	
  ANSI B96.1, “Welded
  Aluminum-Alloy Storage Tanks,” 1981

  	
   

  	
  3.2

  
	
   

  	
   

  	
   

  
	
  ANSI HFS-100, “American
  Standard for Human Factors Engineering of Visual Display Terminal
  Workstations,” 1988

  	
   

  	
  18.8

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

6 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Table 1

AP1000
Codes and Standards (Licensing Basis)

 

	
  Title

  	
   

  	
  DCD
  Section

  
	
   

  	
   

  	
   

  
	
  ANSI N14.6, “Special
  Lifting Devices for Shipping Containers Weighing 10,000 pounds (4500 kg) or
  More,” 1993

  	
   

  	
  3.9, 9.1

  
	
   

  	
   

  	
   

  
	
  ANSI N16.1, “Nuclear
  Criticality Safety in Operations with Fissionable Materials Outside
  Reactors,” 1975

  	
   

  	
  9.1

  
	
   

  	
   

  	
   

  
	
  ANSI
  N16.9, “Validation of Calculational Methods for Nuclear Criticality Safety,”
  1975

  	
   

  	
  9.1

  
	
   

  	
   

  	
   

  
	
  ANSI
  N18.2, “Nuclear Safety Criteria for the Design of Stationary Pressurized
  Water Reactor Plants,” 1973

  	
   

  	
  15.0

  
	
   

  	
   

  	
   

  
	
  ANSI N18.2a, “Nuclear
  Safety Criteria for the Design of Stationary Pressurized Water Reactor
  Plants,” 1975.

  	
   

  	
  3.2

  
	
   

  	
   

  	
   

  
	
  ANSI N101.6, “Atomic
  Industry Facility Design, Construction, and Operation Criteria,” 1972

  	
   

  	
  1A

  
	
   

  	
   

  	
   

  
	
  ANSI N210, “Design
  Objectives for Light Water Reactor Spent Fuel Storage Facilities at Nuclear
  Power Stations,” 1976

  	
   

  	
  9.1

  
	
   

  	
   

  	
   

  
	
  ANSI N237, “Source Term
  Specification,” 1976

  	
   

  	
  1A

  
	
   

  	
   

  	
   

  
	
  ANSI N271, “Containment
  Isolation Provisions for Fluid Systems,” 1976

  	
   

  	
  1A

  
	
   

  	
   

  	
   

  
	
  ANSI N278.1,
  “Self-Operated and Power-Operated Safety-Relief Valves Functional
  Specification Standard,” 1975

  	
   

  	
  5.4

  
	
   

  	
   

  	
   

  
	
  API – American Petroleum
  Institute

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  API 610, “Centrifugal
  Pumps for General Refinery Services,” 1981

  	
   

  	
  3.2

  
	
   

  	
   

  	
   

  
	
  API-620, “Recommended
  Rules for Design and Construction of Large, Welded, Low-Pressure Storage
  Tanks,” Revision 1, April 1985.

  	
   

  	
  3.2

  
	
   

  	
   

  	
   

  
	
  API-650, “Welded Steel
  Tanks for Oil Storage,” Revision 1, February 1984.

  	
   

  	
  3.2

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

7 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Table 1

AP1000
Codes and Standards (Licensing Basis)

 

	
  Title

  	
   

  	
  DCD
  Section

  
	
   

  	
   

  	
   

  
	
  ARI 410, “Forced
  Circulation Air Cooling and Air Heating Coils”, 1991

  	
   

  	
  9.4

  
	
   

  	
   

  	
   

  
	
  ARI – Air Conditioning and
  Refrigeration Institute

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  ARI 620, “Self-Contained
  Humidifiers for Residential Applications,” 1996

  	
   

  	
  9.4

  
	
   

  	
   

  	
   

  
	
  ASCE – American Society of
  Civil Engineers

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  ASCE 4, “Seismic
  Analysis of Safety-Related Nuclear Structures and Commentary,” 1989

  	
   

  	
  3.7

  
	
   

  	
   

  	
   

  
	
  ASCE 7, “Minimum Design
  Loads for Buildings and Other Structures,” 1998

  	
   

  	
  3.7

  
	
   

  	
   

  	
   

  
	
  ASCE 8, “Specification
  for the Design of Cold Formed Stainless Steel Structural Members,” 1990

  	
   

  	
  6.2

  
	
   

  	
   

  	
   

  
	
  ASCE Paper No. 3269
  “Wind Forces on Structures” Transactions of the American Society of Civil
  Engineers, Vol. 126, Part II (1961)

  	
   

  	
  3

  
	
   

  	
   

  	
   

  
	
  ASHRAE – American Society of
  Heating, Refrigeration, and Air Conditioning Engineers

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  ASHRAE 33, “Methods of
  Testing for Rating Forced Circulation Air Cooling and Air Heating Coils,”
  1978

  	
   

  	
  9.4

  
	
   

  	
   

  	
   

  
	
  ASHRAE 52.1
  “Gravimetric and Dust Spot Procedures for Testing Air-Cleaning Devices Used
  in General Ventilation for Removing Particulate Matter,” 1992

  	
   

  	
  9.4

  
	
   

  	
   

  	
   

  
	
  ASHRAE 62, “Ventilation
  for Acceptable Indoor Air Quality,” 1999

  	
   

  	
  9.4

  
	
   

  	
   

  	
   

  
	
  ASHRAE 62, “Ventilation
  for Acceptable Indoor Air Quality,” 1989

  	
   

  	
  6.4

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

8 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Table 1

AP1000
Codes and Standards (Licensing Basis)

 

	
  Title

  	
   

  	
  DCD
  Section

  
	
   

  	
   

  	
   

  
	
  ASHRAE 126, “Method of
  Testing HVAC Air Ducts,” 2000

  	
   

  	
  9.4

  
	
   

  	
   

  	
   

  
	
  ASME — American Society of
  Mechanical Engineers

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  ASME OM Code, “Code for
  Operation and Maintenance of Nuclear Power Plants,” 1995 Edition, 1996
  Addenda

  	
   

  	
  3.9

  
	
   

  	
   

  	
   

  
	
  ASME/ANSI AG-1, “Code
  on Nuclear Air and Gas Treatment,” 1997

  	
   

  	
  1A, 3.2, 3A, 9.4

  
	
   

  	
   

  	
   

  
	
  ASME B16.34, “Valves —
  Flanged and Buttwelding End,” 1996

  	
   

  	
  5.4

  
	
   

  	
   

  	
   

  
	
  ASME B30.2, “Overhead &
  Gantry Cranes,” 1990

  	
   

  	
  9.1

  
	
   

  	
   

  	
   

  
	
  ASME B31.1, “Code for
  Power Piping,” 1989 Edition, 1989 Addenda

  	
   

  	
  5.2

  
	
   

  	
   

  	
   

  
	
  ASME Boiler and
  Pressure Vessel Code, Section II, “Metal Specifications”, 1989 Edition,
  1989Addenda, (Class 1, 2, 3 Piping and Components)

  	
   

  	
  5.2, 5.4

  
	
   

  	
   

  	
   

  
	
  ASME Boiler and
  Pressure Vessel Code, Section III, Rules for Construction of Nuclear Power
  Plant Components, (The baseline used for the evaluations done to support this
  safety analysis report and the Design Certification is the 1998 Edition, 2000
  Addenda, except as follows: the 1989 Edition, 1989 Addenda is used for
  Articles NB-3200, NB-3600, NC-3600, and ND-3600 in lieu of later editions and
  addenda.), (Class 1, 2, 3 Piping and Components)

  	
   

  	
  3.9, 5.2, 5.3,
  5.4

  
	
   

  	
   

  	
   

  
	
  Code Case N-4-11,
  “Special Type 403 Modified Forgings or Bars, Section III, Division 1, Class 1
  and Class CS”

  	
   

  	
  5.2

  
	
   

  	
   

  	
   

  
	
  Code Case N-20-4,
  “SB-163 Nickel-Chromium-Iron Tubing (Alloys 600 and 690) and
  Nickel-Iron-Chromium Alloy 800 at a Specified Minimum Yield Strength of 40.0
  ksi and Cold Worked Alloy 800 at Yield Strength of 47.0 ksi, Section III,
  Division 1, Class 1”

  	
   

  	
  5.2

  
	
   

  	
   

  	
   

  
	
  Code Case N-60-5,
  “Material for Core Support Structures, Section III, Division 1”

  	
   

  	
  5.2

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

9 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Table 1

AP1000
Codes and Standards (Licensing Basis)

 

	
  Title

  	
   

  	
  DCD
  Section

  
	
   

  	
   

  	
   

  
	
  Code Case N-71-18, “
  Additional Material for Subsection NF, Class 1, 2, 3 and MC Component
  Supports Fabricated by Welding, Section III Division 1”

  	
   

  	
  5.2

  
	
   

  	
   

  	
   

  
	
  Code Case N-122-2
  “Stress Indices for Integral Structural Attachments Section III,
  Division 1, Class 1” 1994

  	
   

  	
  5.2

  
	
   

  	
   

  	
   

  
	
  Code Case N-249-14,
  “Additional Materials for Subsection NF, Class 1, 2, 3, and MC Supports
  Fabricated Without Welding, Section III, Division 1”

  	
   

  	
  5.2

  
	
   

  	
   

  	
   

  
	
  Code Case N-284-1,
  “Metal Containment Shell Buckling Design Methods, Section III, Division
  1 Class MC”

  	
   

  	
  5.2

  
	
   

  	
   

  	
   

  
	
  Code Case N-318-5,
  “Procedure for Evaluation of the Design of Rectangular Cross
  Section Attachments on Class 2 or 3 Piping Section III,
  Division”

  	
   

  	
  5.2

  
	
   

  	
   

  	
   

  
	
  Code Case N-391-2,
  “Procedure for Evaluation of the Design of Hollow Circular Cross
  Section Welded Attachments on Class 1 Piping Section III,
  Division 1”

  	
   

  	
  5.2

  
	
   

  	
   

  	
   

  
	
  Code Case N-319-3,
  “Procedure for Evaluation of Stresses in Butt Welding Elbows in Class 1
  Piping, Section III, Division 1”

  	
   

  	
  5.2

  
	
   

  	
   

  	
   

  
	
  Code Case N-392-3,
  “Procedure for Valuation of the Design of Hollow Circular Cross
  Section Welded Attachments on Class 2 and 3 Piping
  Section III, Division 1”

  	
   

  	
  5.2

  
	
   

  	
   

  	
   

  
	
  Code Case-N-474-2,
  “Design Stress Intensities and Yield Strength Values for UNS06690 With a
  Minimum Yield Strength of 35 ksi, Class 1 Components, Section III,
  Division 1”

  	
   

  	
  5.2

  
	
   

  	
   

  	
   

  
	
  ASME Boiler and Pressure Vessel Code, Section IV, “Non-destructive
  Examination,” 1998 Edition, 2000 Addenda, (Class 1, 2, 3 Piping and Components)

  	
   

  	
  5.2

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

10 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Table 1

AP1000
Codes and Standards (Licensing Basis)

 

	
  Title

  	
   

  	
  DCD
  Section

  
	
   

  	
   

  	
   

  
	
  ASME Boiler and Pressure Vessel Code, Section V, “Non-destructive
  Examination,” 1998 Edition, 2000 Addenda, (Class 1, 2, 3 Piping and Components)

  	
   

  	
  5.4

  
	
   

  	
   

  	
   

  
	
  ASME Boiler and
  Pressure Vessel Code, Section VIII, Division 1, “Pressure Vessels,” 1998
  Edition, 2000 Addenda, (Class 1, 2, 3 Piping and Components)

  	
   

  	
  5.2, 9.3

  
	
   

  	
   

  	
   

  
	
  ASME Boiler and
  Pressure Vessel Code, Section IX, “Welding and Brazing Qualifications,”
  1998 Edition, 2000 Addenda, (Class 1, 2, 3 Piping and Components)

  	
   

  	
  5.2

  
	
   

  	
   

  	
   

  
	
  Code Case 2142-1,
  “F-Number Grouping for Ni-Cr-Fe, Classification UNS N06052 Filler Metal,
  Section IX”

  	
   

  	
  5.2

  
	
   

  	
   

  	
   

  
	
  Code Case 2143-1,
  “F-Number Grouping for Ni-Cr-Fe, Classification UNS W86152 Welding Electrode,
  Section IX”

  	
   

  	
  5.2

  
	
   

  	
   

  	
   

  
	
  ASME Code
  Section XI (1998 Edition) and mandatory appendices. (Design provisions,
  in accordance with Section XI, Article IWA-1500, are incorporated
  in the design processes for Class 1 components.) , (Class 1, 2, 3
  Piping and Components)

  	
   

  	
  3.9, 5.2, 5.4

  
	
   

  	
   

  	
   

  
	
  ASME Code Section XI (1996 Edition) Appendix G

  	
   

  	
  5.3

  
	
   

  	
   

  	
   

  
	
  ASME N509 (R1996),
  “Nuclear Power Plant Air Cleaning Units and Components,” 1989

  	
   

  	
  1A, 3A, 9.4

  
	
   

  	
   

  	
   

  
	
  ASME N510, “Testing of
  Nuclear Air Cleaning Systems,” 1989

  	
   

  	
  1A, 9.4

  
	
   

  	
   

  	
   

  
	
  ASME NOG-1,
  “Rules for Construction of Overhead and Gantry Cranes (Top Running
  Bridge, Multiple Girder),” ASME Code, Section IV, Pt. HWL, 1998.

  	
   

  	
  9.1

  
	
   

  	
   

  	
   

  
	
  ASME NQA-1, “Quality
  Management System,” 1989 edition through NQA-1b-1991, Addenda (DCD identifies
  NQA-1 1b 1991 Addenda, however NRC has accepted NQA-1 through NQA-1c-1992,
  Addenda as acceptable via Reg Guide 1.28. NQA-1-1c-1992 is to be specified to
  be consistent with the ASME Section III Code and Addenda specified in
  the DCD.)

  	
   

  	
  17.0

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

11 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Table 1

AP1000
Codes and Standards (Licensing Basis)

 

	
  Title

  	
   

  	
  DCD
  Section

  
	
   

  	
   

  	
   

  
	
  ASME Performance Test
  Code 19.11, 1970

  	
   

  	
  10.4

  
	
   

  	
   

  	
   

  
	
  ASTM — American Society of
  Testing and Materials

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  ASTM A 580,
  “Specification for Stainless and Heat-resisting Steel Wire,” 1990

  	
   

  	
  4.2

  
	
   

  	
   

  	
   

  
	
  ASTM A 609, “Standard
  Specification for Longitudinal Beam Ultrasonic Inspection of Carbon and Low
  Alloy Steel Castings,” 1991

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  ASTM A 615, “Deformed
  and Plain Billet Steel Bars for Concrete Reinforcement,” 2001

  	
   

  	
  3.8

  
	
   

  	
   

  	
   

  
	
  ASTM A 706, “Low Alloy
  Steel Deformed Bars for Concrete Reinforcement,” 2001

  	
   

  	
  3.8

  
	
   

  	
   

  	
   

  
	
  ASTM A 970,
  “Specification for Welded Headed Bars for Concrete Reinforcement,” 1998

  	
   

  	
  3.8

  
	
   

  	
   

  	
   

  
	
  ASTM C 33,
  “Specification for Concrete Aggregates,” 2002

  	
   

  	
  3.8

  
	
   

  	
   

  	
   

  
	
  ASTM C 94,
  “Specifications for Ready-Mixed Concrete,” 2000

  	
   

  	
  3.8

  
	
   

  	
   

  	
   

  
	
  ASTM C 131, “Resistance
  to Abrasion of Small Size Coarse Aggregate by Use of the Los Angeles
  Machine,” 2001

  	
   

  	
  3.8

  
	
   

  	
   

  	
   

  
	
  ASTM C 150,
  “Specification for Portland Cement,” 2002

  	
   

  	
  3.8

  
	
   

  	
   

  	
   

  
	
  ASTM C 260, “Air
  Entraining Admixtures for Concrete,” 2001

  	
   

  	
  3.8

  
	
   

  	
   

  	
   

  
	
  ASTM C 311, “Sampling
  and Testing Fly Ash or Natural Pozzolans for Use as Mineral Admixture in
  Portland Cement Concrete,” 2002

  	
   

  	
  3.8

  
	
   

  	
   

  	
   

  
	
  ASTM C 494, “Chemical
  Admixtures for Concrete,” 1999

  	
   

  	
  3.8

  
	
   

  	
   

  	
   

  
	
  ASTM C 535, “Test
  Method for Resistance to Degradation of Large-Size Coarse Aggregate by
  Abrasion and Impact in the Los Angeles Machine,” 2001

  	
   

  	
  3.8

  
	
   

  	
   

  	
   

  
	
  ASTM C 618, “Fly Ash
  and Raw or Calcined Natural Pozzolans for Use in Portland Cement Concrete,”
  2001

  	
   

  	
  3.8

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

12 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Table 1

AP1000
Codes and Standards (Licensing Basis)

 

	
  Title

  	
   

  	
  DCD
  Section

  
	
   

  	
   

  	
   

  
	
  ASTM D 512, “Chloride
  Ion in Industrial Water,” 1999

  	
   

  	
  3.8

  
	
   

  	
   

  	
   

  
	
  ASTM D 1888, “Particulate
  and Dissolved Matter in Industrial Water.”

  	
   

  	
  3.8

  
	
   

  	
   

  	
   

  
	
  ASTM E 142, “Methods
  for Controlling Quality of Radiographic Testing,” 1986

  	
   

  	
  4.2

  
	
   

  	
   

  	
   

  
	
  ASTM E 165, “Practice
  for Liquid Penetrant Inspection Method,” 1995

  	
   

  	
  5.4

  
	
   

  	
   

  	
   

  
	
  ASTM E 185, “Standard
  Practice for Conducting Surveillance Tests for Light-Water Cooled Nuclear
  Power Reactor Vessels,” 1982

  	
   

  	
  5.3

  
	
   

  	
   

  	
   

  
	
  ASTM E 741, “Standard
  Test Methods for Determining Air Change in a Single Zone by Means of a Tracer
  Gas Dilution,” 2000

  	
   

  	
  6.4, 9.4

  
	
   

  	
   

  	
   

  
	
  AWWA — American Water Works
  Association

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  AWWA D100, “Welded
  Steel Tanks for Water Storage,” 1984

  	
   

  	
  3.2

  
	
   

  	
   

  	
   

  
	
  AWS — American Welding Society  

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  AWS D1.1 Structural
  Welding Code — 2000 - Steel  Covers the design, welding and examination of welded
  structural steel 1/8” and thicker. It allows for both pre-qualified and non
  prequalified welding procedures.  AWS D 1.4-98  Reinforcing
  Steel Welding Code,

  	
   

  	
  3.8.3.2

  
	
   

  	
   

  	
   

  
	
  CMAA — Crane Manufacturers
  Association of America

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  CMAA Specifications,
  “Specification for Electric Overhead Traveling Cranes,” 1999

  	
   

  	
  9.1

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

13 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Table 1

AP1000
Codes and Standards (Licensing Basis)

 

	
  Title

  	
   

  	
  DCD
  Section

  
	
   

  	
   

  	
   

  
	
  FEMA — Federal Emergency
  Management Agency

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  FEMA 356, “Prestandard
  and Commentary for the Seismic Rehabilitation of Buildings,” 2000

  	
   

  	
  3.7

  
	
   

  	
   

  	
   

  
	
  IEEE — Institute of Electrical
  and Electronics Engineers

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 7-4.3.2,
  “IEEE Standard Criteria for Digital Computers in Safety Systems of Nuclear
  Power Generating Stations,” 1993

  	
   

  	
  1A, 7.1

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 98, “IEEE
  Standard for the Preparation of Test Procedures for the Thermal Evaluation of
  Solid Electrical Insulating Materials,” 1984

  	
   

  	
  3D

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 100,
  “IEEE Standard Dictionary of Electrical and Electronic Terms,” 1996

  	
   

  	
  3D

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 141,
  “IEEE Recommended Practice for Electric Power Distribution for Industrial
  Plants,” (IEEE Red Book), 1993

  	
   

  	
  8.3

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 242,
  “IEEE Recommended Practice for Protection and Coordination of Industrial and
  Commercial Power Systems” (IEEE Buff Book), 1986

  	
   

  	
  8.3

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 279,
  “IEEE Standard Criteria for Protection Systems for Nuclear Power Generating
  Stations,” 1971

  	
   

  	
  1A

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 281,
  “IEEE Standard Service Conditions for Power System Communication Equipment,”
  1984

  	
   

  	
  9.5

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 308,
  “IEEE Standard Criteria for Class 1E Power Systems for Nuclear Power
  Generating Stations,” 1991

  	
   

  	
  1A, 8.1, 8.3

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 317,
  “IEEE Standard for Electric Penetrations Assemblies in Containment Structures
  for Nuclear Power Generating Stations,” 1983

  	
   

  	
  1.9, 1A, 8.1,
  8.3

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 323,
  “IEEE Standard for Qualifying Class 1E Equipment for Nuclear Power
  Generating Stations,” 1974

  	
   

  	
  1.9, 1A, 3.2,
  8.1

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

14 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Table 1

AP1000
Codes and Standards (Licensing Basis)

 

	
  Title

  	
   

  	
  DCD
  Section

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 338,
  “IEEE Standard Criteria for the Periodic Surveillance Testing of Nuclear
  Power Generating Stations Safety Systems,” 1987

  	
   

  	
  1.9, 1A, 8.1

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 344,
  “IEEE Recommended Practice for Seismic Qualification of Class 1E
  Equipment for Nuclear Power Generating Stations,” 1987

  	
   

  	
  3.2, 3F, 8.1

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 379,
  “IEEE Standard Application of the Single-Failure Criterion to Nuclear Power
  Generating Station Safety Systems,” 2000

  	
   

  	
  1A, 8.1

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 381,
  “IEEE Standard Criteria for Type Test of Class 1E Modules used in
  Nuclear Power Generating Stations,” 1977

  	
   

  	
  3D

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 382,
  “IEEE Standard for Qualification of Actuators for Power-Operated Valve
  Assemblies with Safety-Related Functions for Nuclear Power Plants,” 1996

  	
   

  	
  1A, 8.1

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 383,
  “IEEE Standard for Type Test of Class 1E Electric Cables, Field Splices,
  and Connections for Nuclear Power Generating Stations,” 1974

  	
   

  	
  8.1, 9.5

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 384,
  “IEEE Standard Criteria for Independence of Class 1E Equipment and
  Circuits,” 1981

  	
   

  	
  1A, 1.9, 8.1,
  8.3

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 420,
  “IEEE Standard for the Design and Qualification of Class 1E Control
  Boards, Panels, and Racks Used in Nuclear Power Generating Stations,” 1982

  	
   

  	
  7.1

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 422,
  “Guide for the Design and Installation of Cable Systems in Power Generating
  Stations,” 1986

  	
   

  	
  8.3

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 450,
  “IEEE Recommended Practice for Maintenance, Testing, and Replacement of
  Vented Lead-Acid Batteries for Stationary Applications,” 1995

  	
   

  	
  8.1, 8.3

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 484,
  “IEEE Recommended Practice for Installation Design and Installation of Vented
  Lead-Acid Batteries for Stationary Applications,” 1996

  	
   

  	
  1A, 8.1

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

15 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Table 1

AP1000
Codes and Standards (Licensing Basis)

 

	
  Title

  	
   

  	
  DCD
  Section

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 485,
  “IEEE Recommended Practice for Sizing Lead-Acid Batteries for Stationary
  Applications,” 1997

  	
   

  	
  8.3

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 494,
  “IEEE Standard Method for Identification of Documents Related to
  Class 1E Equipment and Systems for Nuclear Power Generating Stations,”
  1974

  	
   

  	
  3D

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 535,
  “IEEE Standard for Qualification of Class 1E Lead Storage Batteries for
  Nuclear Power Generating Stations,” 1986

  	
   

  	
  1A

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 572,
  “IEEE Standard for Qualification of Class 1E Connection Assemblies for
  Nuclear Power Generating Stations,” 1985

  	
   

  	
  3D

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 603,
  “IEEE Standard Criteria for Safety Systems for Nuclear Power Generating
  Stations,” 1991

  	
   

  	
  1A, 7.1

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 627,
  “IEEE Standard for Design Qualification of Safety System Equipment Used in
  Nuclear Power Generating Stations,” 1980

  	
   

  	
  7.1

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 649,
  “IEEE Standard for Qualifying Class 1E Motor Control Centers for Nuclear
  Power Generating Stations,” 1991

  	
   

  	
  3D

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 650,
  “IEEE Standard for Qualification of Class 1E Static Battery Chargers and
  Inverters for Nuclear Power Generating Stations,” 1990

  	
   

  	
  3D

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 665,
  “IEEE Guide for Generating Station Grounding,” 1995

  	
   

  	
  8.3

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 741,
  “IEEE Standard Criteria for the Protection of Class 1E Power Systems and
  Equipment in Nuclear Power Generating Stations,” 1997

  	
   

  	
  1A, 8.1, 8.3

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 828,
  “IEEE Standard for Software Configuration Management Plans,” 1990

  	
   

  	
  7.1

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 829,
  “IEEE Standard for Software Test Configuration,” 1983

  	
   

  	
  7.1

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

16 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Table 1

AP1000
Codes and Standards (Licensing Basis)

 

	
  Title

  	
   

  	
  DCD
  Section

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 830,
  “Recommended Practice for Software Requirements Specifications,” 1993

  	
   

  	
  7.1

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 946,
  “IEEE Recommended Practice for the Design of DC Auxiliary Power Systems for
  Generating Stations,” 1992

  	
   

  	
  8.3

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 1012,
  “IEEE Standard for Software Verification and Validation Plans,” 1986

  	
   

  	
  7.1

  
	
   

  	
   

  	
   

  
	
  IEEE Std 1023-2004,
  “IEEE Recommended Practice for the Application of Human Factors Engineering
  to Systems, Equipment and Facilities of Nuclear Power Generating Stations and
  Other Nuclear Facilities.”

  	
   

  	
  18.8

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 1028,
  “IEEE Standard for Software Reviews and Audits,” 1988

  	
   

  	
  7.1

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 1042,
  “IEEE Guide to Software Configuration Management,” 1987

  	
   

  	
  7.1

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 1050,
  “IEEE Guide for Instrumentation and Control Equipment Grounding in Generating
  Stations,” 1996

  	
   

  	
  8.3, 7.1

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 1074,
  “Standard for Developing Software Life Cycle Processes,” 1995

  	
   

  	
  7.1

  
	
   

  	
   

  	
   

  
	
  IEEE Standard 1202,
  “IEEE Standard for Flame Testing of Cables for Use in Cable Tray in
  Industrial and Commercial Occupancies,” 1991

  	
   

  	
  8.1, 1A, 9.5

  
	
   

  	
   

  	
   

  
	
  IEEE Std 1289-1998,
  “IEEE Guide for the Application of Human Factors Engineering in the Design of
  Computer-Based Monitoring and Control Displays for Nuclear Power Generating
  Stations.”

  	
   

  	
  18.8

  
	
   

  	
   

  	
   

  
	
  IEEE Standard C37.98,
  “IEEE Standard for Seismic Testing of Relays,” 1987

  	
   

  	
  3D

  
	
   

  	
   

  	
   

  
	
  ISA — Instrumentation, Systems
  and Automation Society

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  ISA S7.3, “Quality
  Standard for Instrument Air,” 1981

  	
   

  	
  9.3

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

17 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Table 1

AP1000
Codes and Standards (Licensing Basis)

 

	
  Title

  	
   

  	
  DCD
  Section

  
	
   

  	
   

  	
   

  
	
  MIL — Military Standards and
  Specifications

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  MIL-HDBK-759C, “Human
  Engineering Design Guidelines,” 1995

  	
   

  	
  6.4

  
	
   

  	
   

  	
   

  
	
  MIL-STD 1472E, “Human
  Engineering,” 1996

  	
   

  	
  6.4

  
	
   

  	
   

  	
   

  
	
  NEMA — National Electrical
  Manufacturers Association

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  NEMA MG-1, “Motors and
  Generators,” Revision 1, 1998

  	
   

  	
  3.2

  
	
   

  	
   

  	
   

  
	
  NEMA Standard
  Publication No. VE 1-1998, Metallic Cable Tray Systems

  	
   

  	
  3F

  
	
   

  	
   

  	
   

  
	
  NFPA — National Fire Protection
  Association

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  NFPA 10, “Standard for
  Portable Fire Extinguishers,” 1998

  	
   

  	
  9.5

  
	
   

  	
   

  	
   

  
	
  NFPA 13, “Standard for
  the Installation of Sprinkler Systems,” 1999

  	
   

  	
  9.5

  
	
   

  	
   

  	
   

  
	
  NFPA 14, “Standard for
  Installation of Standpipe, Private Hydrants, and Hose Systems,” 2000

  	
   

  	
  9.5

  
	
   

  	
   

  	
   

  
	
  NFPA 15, “Standard for
  Water Spray Fixed Systems for Fire Protection,” 2001

  	
   

  	
  9.5

  
	
   

  	
   

  	
   

  
	
  NFPA 20, “Standard for
  the Installation of Stationary Pumps for Fire Protection,” 1999

  	
   

  	
  9.5

  
	
   

  	
   

  	
   

  
	
  NFPA 22, “Standard for
  Water Tanks for Private Fire Protection,” 1998

  	
   

  	
  9.5

  
	
   

  	
   

  	
   

  
	
  NFPA 24, “Standard for
  Installation of Private Fire Service Mains and Fire Protection,” 1995

  	
   

  	
  9.5

  
	
   

  	
   

  	
   

  
	
  NFPA 30, “Flammable and Combustible Liquids Code,” 2000

  	
   

  	
  9.5

  
	
   

  	
   

  	
   

  
	
  NFPA 50A, “Standard for
  Gaseous Hydrogen Systems at Consumer Sites,” 1999

  	
   

  	
  9.5

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

18 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Table 1

AP1000
Codes and Standards (Licensing Basis)

 

	
  Title

  	
   

  	
  DCD
  Section

  
	
   

  	
   

  	
   

  
	
  NFPA 50B, “Standard for
  Liquefied Hydrogen Systems at Consumer Sites,” 1999

  	
   

  	
  9.5

  
	
   

  	
   

  	
   

  
	
  NFPA 70, “National
  Electrical Code (NEC),” 1999

  	
   

  	
  8.3, 9.5

  
	
   

  	
   

  	
   

  
	
  NFPA 72, “National Fire
  Alarm Code,” 1999

  	
   

  	
  9.5

  
	
   

  	
   

  	
   

  
	
  NFPA 90A, “Installation
  of Air-Conditioning and Ventilation Systems,” 1999

  	
   

  	
  9.4

  
	
   

  	
   

  	
   

  
	
  NFPA 92A, “Recommended
  Practice for Smoke Control Systems,” 2000

  	
   

  	
  9.4, 9A

  
	
   

  	
   

  	
   

  
	
  NFPA 780, “Standard for
  the Installation of Lighting Protection Systems,” 2000

  	
   

  	
  8.3, 9.5

  
	
   

  	
   

  	
   

  
	
  NFPA 804, “Standard for
  Fire Protection for Advanced Light Water Reactor Electric Generating Plants,”
  2001

  	
   

  	
  9.5

  
	
   

  	
   

  	
   

  
	
  SMACNA — Sheet Metal and Air
  Conditioning Contractors National Association

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  SMACNA, “HVAC Duct
  Construction Standards - Metal and Flexible,” Second Edition 1995

  	
   

  	
  3A, 9.4

  
	
   

  	
   

  	
   

  
	
  SMACNA, “HVAC Systems —
  Testing, Adjusting, and Balancing,” 1993

  	
   

  	
  9.4

  
	
   

  	
   

  	
   

  
	
  SMACNA, “Rectangular
  Industrial Duct Construction Standards,” 1980

  	
   

  	
  9.4

  
	
   

  	
   

  	
   

  
	
  SMACNA, “HVAC Duct
  Construction Standards - Metal and Flexible,” 1985

  	
   

  	
  3.2

  
	
   

  	
   

  	
   

  
	
  SMACNA, “Round
  Industrial Duct Construction Standard,” 1999

  	
   

  	
  9.4

  
	
   

  	
   

  	
   

  
	
  SMACNA, “HVAC Duct
  Leakage Test Manual,” 1985

  	
   

  	
  9.4

  
	
   

  	
   

  	
   

  
	
  UBC — Uniform Building Code

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  UBC, “Uniform Building
  Code,” 1997

  	
   

  	
  3.2

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

19 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Table 1

AP1000
Codes and Standards (Licensing Basis)

 

	
  Title

  	
   

  	
  DCD
  Section

  
	
   

  	
   

  	
   

  
	
  UL — Underwriters
  Laboratories, Inc.

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  UL 555, “Safety Fire
  Dampers,” 1999

  	
   

  	
  9.4

  
	
   

  	
   

  	
   

  
	
  UL 555S, “Leakage Rated
  Dampers for Use in Smoke Control Systems,” 1999

  	
   

  	
  9.4

  
	
   

  	
   

  	
   

  
	
  UL 586,
  “High-Efficiency, Particulate, Air-Filter Units,” 1996

  	
   

  	
  9.4

  
	
   

  	
   

  	
   

  
	
  UL 900, “Test
  Performance of Air-Filter Unit,” 1994

  	
   

  	
  9.4

  
	
   

  	
   

  	
   

  
	
  UL 1995, “Heating and
  Cooling Equipment,” 1995

  	
   

  	
  9.4

  
	
   

  	
   

  	
   

  
	
  UL 1996, “Electric Duct
  Heating,” 1996

  	
   

  	
  9.4

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

20 of 21

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Table 2

AP1000 Codes and Standards (not found in Licensing Basis)

 

	
  Title

  	
   

  	
  Reference

  
	
   

  	
   

  	
   

  
	
  ASME NQA-2 Quality
  Assurance Requirements for Nuclear Power Plants 1989 Edition, through
  NQA-1c-1992, Addenda

  	
   

  	
  None

  
	
   

  	
   

  	
   

  
	
  American Society for
  Nondestructive Testing SNT-TC-1A, “Recommended Practice for Non-Destructive
  Testing 1992 Edition.

  	
   

  	
  None

  
	
   

  	
   

  	
   

  
	
  CP-189 Qualification
  and Certification of Nondestructive Testing Personnel 1995 Edition

  	
   

  	
  None

  

 

“[**]” in this Exhibit 10.01 indicates material that has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.

 

21 of 21

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT O-1

 

Proprietary Data Agreement

 

[**This entire five-page exhibit
has been omitted pursuant to a request for confidential treatment and filed
separately with the Securities and Exchange Commission.]

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT O-2

 

List of Intellectual Property Subject to
Third-Party License Terms

 

[**This entire one-page exhibit has been omitted
pursuant to a request for confidential treatment and filed separately with the
Securities and Exchange Commission.]

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT
P-1

AP1000 —Major
Subcontractors / Suppliers

 

	
  Approved Supplier

  	
   

  	
  Potential
  Components / Services to be Supplied

  
	
  [**]

  	
   

  	
  I&C equipment

  
	
  [**]

  	
   

  	
  Gas packages

  
	
  [**]

  	
   

  	
  S/G, RV and Head,
  Containment Air Baffle, modules, tanks, PZR, Rx coolant piping, containment
  vessel

  
	
  [**]

  	
   

  	
  Electrodeionization
  Units

  
	
  [**]

  	
   

  	
  Diesel Generators

  
	
  [**]

  	
   

  	
  Containment Vessel,
  Containment Air Baffle, PZR, Containment Erection

  
	
  [**]

  	
   

  	
  Valves

  
	
  [**]

  	
   

  	
  Valves

  
	
  [**]

  	
   

  	
  Valves

  
	
  [**]

  	
   

  	
  Reactor Coolant Pumps,
  CRDMS, BOP Pumps

  
	
  [**]

  	
   

  	
  S/G, RV and Head, Rx
  Internals, PZR, Rx coolant piping

  
	
  [**]

  	
   

  	
  Valves

  
	
  [**]

  	
   

  	
  Modules

  
	
  [**]

  	
   

  	
  I&C equipment

  
	
  [**]

  	
   

  	
  Valves

  
	
  [**]

  	
   

  	
  Instrumentation

  
	
  [**]

  	
   

  	
  Batteries, Battery
  chargers

  
	
  [**]

  	
   

  	
  S/G, RV and Head, PZR

  
	
  [**]

  	
   

  	
  Valves, BOP Pumps

  
	
  [**]

  	
   

  	
  Breakers

  
	
  [**]

  	
   

  	
  Modules

  
	
  [**]

  	
   

  	
  Batteries, Battery
  chargers

  
	
  [**]

  	
   

  	
  Make-up tanks,
  Accumulator Tanks

  
	
  [**]

  	
   

  	
  Pumps

  
	
  [**]

  	
   

  	
  Squib valves,
  containment electrical penetrations

  
	
  [**]

  	
   

  	
  Incore Instruments

  
	
  [**]

  	
   

  	
  Containment Air Baffle,
  PZR

  
	
  [**]

  	
   

  	
  Various pumps

  
	
  [**]

  	
   

  	
  Rx Internals

  
	
  [**]

  	
   

  	
  RHR pumps

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 1 of 2

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  Approved Supplier

  	
   

  	
  Potential
  Components / Services to be Supplied

  
	
  [**]

  	
   

  	
  Modules, Containment
  Vessel

  
	
  [**]

  	
   

  	
  Batteries, Battery
  chargers

  
	
  [**]

  	
   

  	
  Refueling Equipment,
  Polar Crane, other cranes

  
	
  [**]

  	
   

  	
  Valves

  
	
  [**]

  	
   

  	
  Reactor Integrated Head
  Package Components

  
	
  [**]

  	
   

  	
  Reactor Integrated Head
  Package Components

  
	
  [**]

  	
   

  	
  Rx Internals components

  
	
  [**]

  	
   

  	
  Variable Frequency
  Drive Unit for RCPs

  
	
  [**]

  	
   

  	
  Valves

  
	
  [**]

  	
   

  	
  Cooling towers

  
	
  [**]

  	
   

  	
  Valves

  
	
  [**]

  	
   

  	
  Containment Air Baffle

  
	
  [**]

  	
   

  	
  Valves

  
	
  [**]

  	
   

  	
  Valves

  
	
  [**]

  	
   

  	
  Piping (Supplier),
  Modules

  
	
  [**]

  	
   

  	
  Valves, BOP Pumps

  
	
  [**]

  	
   

  	
  Rx coolant piping

  
	
  [**]

  	
   

  	
  Turbine Generator,
  Electrical distribution, heavy components

  
	
  [**]

  	
   

  	
  Reflective Insulation

  
	
  [**]

  	
   

  	
  Valves

  
	
  [**]

  	
   

  	
  BOP Pumps

  
	
  [**]

  	
   

  	
  Valves

  
	
  [**]

  	
   

  	
  Instrumentation

  
	
  [**]

  	
   

  	
  Transformers, load
  centers, switchgear

  
	
  [**]

  	
   

  	
  Rx Internals, CRDMs

  
	
  [**]

  	
   

  	
  Valves

  
	
  [**]

  	
   

  	
  Cooling Tower

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 2 of 2

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT
P-2

SUBCONTRACTORS
FOR

SITE
CONSTRUCTION AND RELATED FIELD SERVICES

 

	
  WORK
  SCOPE

  	
  POTENTIAL
  SUBCONTRACTORS

  
	
  Grubbing and Site
  Clearing

  	
  [**]

  
	
  Excavation and Backfill

  	
  [**]

  
	
  Surveying Control & Support

  	
  [**]

  
	
  Grading & Paving

  	
  [**]

  
	
  Railroad Trackwork

  	
  [**]

  
	
  Major Lifts and Rigging

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

1

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  WORK
  SCOPE

  	
  POTENTIAL
  SUBCONTRACTORS

  
	
  Pre-Engineered Buildings
  ( Offices, Shops, Warehouses)

  	
  [**]

  
	
  Soils &
  Concrete Testing Services

  	
  [**]

  
	
  Specialty Machining &
  Welding

  	
  [**]

  
	
  Caissons/Pilings (if
  applicable)

  	
  [**]

  
	
  Field Erected Tanks

  	
  [**]

  
	
  HVAC (Furnish &
  Install)

  	
  [**]

  
	
  Underground Utilities

  	
  [**]

  
	
  Transformers/Switchyard

  	
  [**]

  
	
  Cooling Tower

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

2

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  WORK
  SCOPE

  	
  POTENTIAL
  SUBCONTRACTORS

  
	
  Built-Up Roofing

  	
  [**]

  
	
  Specialty Coatings

  	
  [**]

  
	
  Fire Protection/
  Sprinklers

  	
  [**]

  
	
  Fire Alarm & Detection System

  	
  [**]

  
	
  Fireproofing

  	
  [**]

  
	
  Containment Erection

  	
  [**]

  
	
  Pipe &
  Equipment Insulation

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

3

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

	
  WORK
  SCOPE

  	
  POTENTIAL
  SUBCONTRACTORS

  
	
  Concrete Batch Plant
  Furnish & Erect

  	
  [**]

  
	
  Concrete Supply &
  Pumping

  	
  [**]

  
	
  Elevators

  	
  [**]

  
	
  Piping (Supplier)

  	
  [**]

  
	
  Module Fabrication

  	
  [**]

  
	
  Instrumentation

  	
  [**]

  
	
  Janitorial Services

  	
  [**]

  
	
  Construction Security

  	
  [**]

  
	
  Construction Fencing

  	
  [**]

  
	
  Waste Management
  Services

  	
  [**]

  
	
  DEWATERING Services

  	
  [**]

  
	
  Total Site Development

  	
  [**]

  
	
  Off-critical path BOP
  electrical/mechanical

  	
  [**]

  
	
  Turbine Island

  	
  [**]

  
	
  Major Heavy
  Civil-Rebar, Formwork, Concrete Placement

  	
  [**]

  

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

4

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT Q

Equipment
With Owner-Designated Witness And Hold Points

 

	
  Potential Components to be
  Supplied

  	
   

  	
  Supplier

  
	
  Steam Generators

  	
   

  	
  Doosan Heavy Industries &
  Construction Co., Ltd.

  
	
  Reactor Vessel

  	
   

  	
  Doosan Heavy Industries &
  Construction Co., Ltd.

  
	
  Reactor Vessel Head

  	
   

  	
  Doosan Heavy Industries &
  Construction Co., Ltd.

  
	
  Main Turbine and
  Generator

  	
   

  	
  Toshiba

  
	
  Pressurizer

  	
   

  	
  Ansaldo Camozzi

  
	
  Reactor Coolant Pumps

  	
   

  	
  Curtiss-Wright
  Electro-Mechanical Division

  
	
  Control Rod Drive
  Mechanisms

  	
   

  	
  Curtiss-Wright
  Electro-Mechanical Division

  
	
  Reactor Coolant Piping

  	
   

  	
  Tioga Pipe Supply

  
	
  Core Makeup Tanks

  	
   

  	
  IHI Corporation

  

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
1 of 1

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT
R

Description
Of Site

 

The Units will be located
on the property owned by SCE&G south of the existing VC Summer Unit 1. The
Site is located in Jenkinsville, South Carolina.

 

The Site Boundary and
Site plan drawings are provided in Figures attached.

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 1 of 5

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

V.C. Summer Unit 2 and 3
Site Boundary

 

 

“[**]”
in this Exhibit 10.01 indicates material that has been omitted pursuant to a
request for confidential treatment and filed separately with the Securities and
Exchange Commission.

 

Page 2 of 5

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
3 of 5

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
4 of 5

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

 

“[**]” in this Exhibit 10.01 indicates
material that has been omitted pursuant to a request for confidential treatment
and filed separately with the Securities and Exchange Commission.

 

Page
5 of 5

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT S

EEO and Small Business Regulations

 

To the extent required by
applicable Laws, all government regulations concerning equal employment,
affirmative action and the utilization of small, small disadvantaged and
women-owned businesses are incorporated into this Agreement by reference,
including but not limited to, the following federal regulations, executive
orders, and the statutory authority for these regulations as referenced in the
regulations:

 

If this Agreement (together with other contracts with Contractor) is in
the amount of $10,000.00 or more and not otherwise exempt:

 

1.               41 C.F.R. § 60-1.4(a), Equal Opportunity Clause, 48 C.F.R. § 52.222-26;
48 C.F.R. § 52.222-21, Prohibition of Segregated Facilities.

2.               41 C.F.R. § 60-741.4, Section 503 of the Rehabilitation Act of 1973 and
41 C.F.R. § 60-741.5(a), Equal Opportunity for Workers with Disabilities; 48
C.F.R. § 52.222-36.

 

If this Agreement (together with other contracts with
Contractor) is in the amount of $25,000 or more and not otherwise exempt:

 

1.               41 C.F.R. § 60-250.5(a), Equal Opportunity for Special Disabled Veterans,
Veterans of the Vietnam Era, Recently Separated Veterans, and Other Protected
Veterans; 48 C.F.R. § 52.222-35.

 

If Contractor has 50 or more
employees and if this Agreement is an amount of $50,000 or more and is not
otherwise exempt:

 

1.               48 C.F.R. § 22.804-1, Affirmative Action
Programs; 48 C.F.R. § 52.222-25, Affirmative Action Compliance.

 

If this
Agreement is in an amount that may exceed $550,000.00 and is not otherwise
exempt:

 

1.               48 C.F.R. § 52.219-8, Utilization of Small Business Concerns.

2.               48 C.F.R. § 52.219-9, Small Business and Small Disadvantaged and
Women-Owned Small Business Subcontracting Plan Clause.

3.               Contractor shall provide Owner with an aggressive Commercial Plan that
meets both the spirit and intent of Title 48 of the C.F.R., while saving Owner
some of the administrative costs associated with the full implementation of a
Small Business Subcontracting Plan per 48 C.F.R. § 52.219.9.

 

To the extent required by
law, executive order or regulation:

 

1.               29 C.F.R. Part 1625,
Executive Order 11141 (Discrimination on the Basis of Age), Public Law 90-202
(Age Discrimination in Employment Act of 1967) and the Age Discrimination in
Employment Act.

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

1 of 2

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Contractor
and its Subcontractors hereunder by virtue of any or all of the
above-referenced statutory, regulatory, or executive order requirement, or
other requirements, may be required to comply with certain record keeping,
reporting or affirmative action requirements, and those requirements are
incorporated herein by reference.  It
shall be the obligation of Contractor and its Subcontractors to make themselves
aware of and to understand the legislative, executive, and regulatory
requirements that apply to their performance of obligations under this
Agreement.  Failure to do so shall not
excuse their application to this Agreement.

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

2 of 2

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT T

[Not Used]

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

EXHIBIT U

Owner Controlled Insurance Program (OCIP)
Description and Terms

 

Capitalized terms used
herein and not otherwise defined herein have the meanings assigned to such
terms in the Agreement to which this Exhibit U is appended.

 

Owner has the option of
implementing an Owner Controlled Insurance Program (“OCIP”) for Phase II. At
least six (6) months prior to the beginning of Phase II, Contractor shall
complete and provide to Owner an Insurance Premium Worksheet (the “Insurance
Premium Worksheet”) in a form provided by Owner.  The Insurance Premium Worksheet will require
Contractor to disclose its estimated costs and markups for insurance.  Owner will utilize the contents of this
Insurance Premium Worksheet to decide whether or not to implement the
OCIP.  Owner may review the Insurance
Premium Worksheet with third party insurance brokers who are not competitors of
the Contractor subject to Section 19.2(c), and Contractor agrees to cooperate
with such review. Owner will notify Contractor at least three (3) months prior
to start if Phase II if Owner will not exercise this option.  If such notice is not received by such date,
Owner shall be deemed to have exercised such option.  Should Owner elect not to implement the OCIP,
Contractor will provide either a CCIP program or a standard insurance program
consistent with the insurance coverages required by Section 16.2 of the
Agreement, in either case, on a Time and Material Basis.

 

Owner will, through the
OCIP, procure and maintain at all times, starting on the first day of  Phase II and continuing during the
performance of the Agreement, unless canceled as noted herein, and for such
extension periods for completed operations, at its own expense, Workers’
Compensation and Employer’s Liability, Commercial General Liability, and
Umbrella/Excess Liability insurance coverages. 
The deductibles under the OCIP shall be the responsibility of Owner. If
an OCIP is implemented by Owner, then Contractor and all applicable
Subcontractors will be required to participate as further described in this
Exhibit.

 

Enrolled
Parties:  “Enrolled Parties” will consist of (a) Contractor
and Subcontractors whose principal place of performance of the Work is on the
Site; provided that the cost of the Work to be performed by Contractor or any
such Subcontractor exceeds an amount designated by Owner and (b) such other
persons or entities as Owner may designate who perform direct labor at the Site
or sites incidental to the Work. Owner may also elect to cover its architects,
engineers and consultants.  Temporary
labor services and leasing companies are also included within this definition.

 

While the OCIP is
intended to provide coverage for the Site, the OCIP is not intended to meet all
of the Enrolled Parties’ insurance needs. 
The insurance described in the “Insurance Provided by the
Owner” section herein will not apply with respect to Contractor or
Subcontractors who are not enrolled in accordance with the provisions
herein.  The OCIP does not provide
coverage for Automobile Liability, Contractor’s Equipment or Performance
Bonds.  Enrolled Parties will be
responsible for procuring and maintaining, at their own expense (except to the
extent otherwise provided herein on a Time and Materials Basis or Target Price
Basis) throughout the term of the Agreement, the insurance for offsite
operations described in the “Insurance Required of
Enrolled Parties” section herein. 
Notwithstanding the foregoing, Parties will determine those
Subcontractors that are not required to procure and maintain, at their own
expense, coverage in

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

Page
1 of 9

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

accordance with the
requirements as outlined in the “Insurance Required of
Enrolled Parties” section of this Exhibit.

 

Contractor will be
responsible for requiring that a Subcontractor who is not an Enrolled Party,
procure and maintain during the term of this Agreement the insurance coverages
required under “Insurance Requirements of Excluded Parties”
section herein, unless waived by Contractor consistent with its normal
practices.  Should Contractor waive such
insurance requirements of any Subcontractor, [**].

 

Owner’s Insurance Obligations; Enrolled Party’s
Obligations

 

Owner assumes no obligation to provide insurance other
than that contemplated under the OCIP, including the Project Insurance Manual
(described below), the builder’s all risk insurance, nuclear liability
coverage, nuclear operating property insurances, and any other coverages which
Owner is required to provide hereunder. Any type of insurance coverage or
limits of liability (a) which are not provided by (i) the OCIP or (ii) Owner’s
or Contractor’s other coverages provided under this Agreement and required to
be carried hereunder and (b) which any Enrolled Party desires for its own
protection will be its sole responsibility and expense and will not be billed
to Owner.

 

Excluded Parties: Owner anticipates that the following types of
Subcontractor and other participants and/or activities (“Excluded Parties”)
will not be enrolled in or covered by the OCIP program: Offsite fabricators and
fabrication, vendors, suppliers (not performing or subcontracting
installation), material dealers, offsite guards and guard services, offsite
janitorial services, offsite cranes, crane operations, and crane operators,
offsite demolition, offsite blasting, truckers (trucking to the Site where
delivery is the only scope of Work to be performed), offsite asbestos abatement
(if any), or other hazardous waste handling and/or removal, Subcontractors and
others whose sole function is to transport, pickup, deliver or carry materials,
supplies, tools equipment, parts or other items to or from the  Site, or who do not perform any actual onsite
labor.  Any other entity or activity
specifically determined by Owner, at the time of enrollment application, to be
excluded will not be covered by insurance purchased by Owner through the OCIP
except under Owner approved exceptions.

 

Unless specifically
approved by Owner in writing, the policies set forth in the “Insurance Provided by the Owner” section herein will cover
only those operations of the Enrolled Parties performed in connection with the
Work at the Site.

 

Coverage under the OCIP
will remain in force through Substantial Completion of the Work including punch
list Work, but will not include call back and Work required by the Warranties
after Substantial Completion.  Should the
coverage be cancelled prior to Substantial Completion by the Owner, coverage
will revert back to that stated in the “Insurance Required of
Enrolled Parties” section herein. 
Such coverages shall be provided at Owner’s cost.

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

Page
2 of 9

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Owner’s
Election To Discontinue OCIP Coverage

 

If Owner, for any reason, is unable to furnish
coverage, elects to discontinue the OCIP, modifies the limits of liability
provided in the OCIP, or requests that an Enrolled Party withdraw from the
OCIP, then, upon thirty (30) days written notice from Owner, the Enrolled Party
specified by Owner in such notice, will obtain at Owner’s expense, and
thereafter maintain during the performance of the Work, all (or a portion
thereof as specified by Owner) of the insurance required to be provided
hereunder, and Owner will thereafter no longer be obligated to furnish all or a
part of such insurance through the OCIP. 
The form, content, limits of liability
and cost of such insurance and the insurer issuing such insurance secured by
the Enrolled Party pursuant to the provisions of this section will be subject
to the Owner’s approval, after consultation with Contractor.

 

Prior to the termination
of the OCIP, Contractor will complete a new Insurance Premium Worksheet.  Owner may utilize the contents of this
Insurance Premium Worksheet to decide whether to discontinue the OCIP.  The Insurance Premium Worksheet will require
Contractor to disclose its estimated costs and markups for insurance.  Owner may review the Insurance Premium
Worksheet with third party consultants, and Contractor agrees to cooperate with
such review.  Should Owner elect to discontinue
the OCIP, Contractor will provide a CCIP program or the insurance coverages
required by Section 16.2 of the Agreement on a Time and Material Basis, which
amounts will be paid by Owner.

 

[**]

 

Insurance
Provided By The Owner

 

Participation in this
OCIP is mandatory for designated Subcontractors but not automatic.  The OCIP will provide the Enrolled Party with
insurance described in this section.

 

Owner will provide each
Enrolled Party in the OCIP a Project Insurance Manual, which will include a
summary of the insurance coverage, loss control procedures and claim
procedures, as well as enrollment forms and reporting requirements for the
OCIP.  The Enrolled Party will use and
comply with the requirements contained in said manual.  In addition, Owner shall provide a copy (or
if the policy does not yet exist, a summary) of all such OCIP policies for
Contractor’s review at the Site and approval by Contractor (which approval will
not be unreasonably withheld or delayed) prior to the placement of such
coverage.

 

Workers’
Compensation Insurance - Statutory Limits of the Workers’ Compensation Laws of the State of
South Carolina with Coverage B - Employer’s Liability (with limits of [**] for
Bodily Injury by accident, [**] for Bodily Injury by disease and

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

Page
3 of 9

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

[**] policy limit Bodily
Injury by disease), covering operations of the Enrolled Party performed on or
incidental to Work at the Site.

 

Commercial
General Liability Insurance - (Excluding Automobile and Professional
Liability but including Products Liability) in form providing coverage not less than a Commercial
General Liability insurance policy, including hazards of explosion, collapse,
underground, independent contractor(s), Enrolled Parties and their employees as
additional insureds, completed operations for a minimum of [**] after
Substantial Completion of the Work, broad form contractual liability coverage
and  personal injury liability coverage
for claims arising out of the Work for personal injury, bodily injury and
property damage in policy or policies of insurance such that the total
available limits, reinstated annually to all insureds combined will not be less
than [**].

 

Coverage
will apply only to Work performed at the Site. 
Such insurance will not include coverage for products liability for any
product(s) manufactured, assembled, or otherwise worked upon away from the Site
for any Enrolled Party or Excluded Party performing such offsite work.

 

Umbrella/Excess
Liability Insurance  - Having limits of [**], covering the interests of all
Enrolled Parties with the following coverages.

 

Primary And
Non-Contributory:  All such OCIP
policies shall include the Enrolled Parties and their employees, and cover the
Enrolled Parties’ liability.  Workers’ Compensation and Employer’s
Liability insurance is primary and non-contributory with respect to any persons
(other than Owner’s employees) covered by such insurance.  Commercial General Liability, and
Umbrella/Excess insurance is primary insurance and non-contributory with any
other insurance carried by Enrolled Parties.

 

Assignment: 
In consideration of Owner purchasing OCIP insurance as stated above, the
Enrolled Parties will assign to Owner all return premiums, premium refunds,
dividends and other monies due or to become due under the insurance which Owner
provides under the OCIP, all of which will inure to the benefit of the
OCIP.  The Enrolled Parties will execute
such further documentation as may be required by Owner to effect this
assignment.  Contractor will not charge
the Owner either directly or in its markups any premiums for duplicate
insurance coverages.

 

Waiver Of
Subrogation Rights:   The Enrolled Parties and Owner
each on their own behalf and on behalf of anyone claiming by, through or under
them, whether by way of subrogation or otherwise, hereby waive any and all
subrogation rights which they may now or hereafter have against each other and
their Affiliates, as well as the successors and assigns of each, in connection
with the performance of the Work, to the extent such subrogation rights are not
the result of any intentional wrongful (i) act or (ii) omission of the party
causing such loss and are covered losses under the insurance provided
hereunder.  In addition, the Owner hereby
waives any and all rights of recovery for any deductibles under any of the OCIP
insurances, howsoever such claim arises, including fault, negligence or strict
liability.

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

Page
4 of 9

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Enrolled Parties’
Responsibilities

 

Contract
Insurance Cost

 

Failure
of Enrolled Parties to enforce the enrollment of all applicable Subcontractors
does not relieve the Enrolled Parties of the financial responsibility for their
Subcontractors’ insurance deductions. 
Owner maintains the right to pursue insurance deductions for all
applicable Subcontractors through Contractor. Upon completion of Work, or on policy expiration,
Owner’s insurance carriers have the right to audit payroll records for the sole
purpose of pursuing such insurance deductions.

 

Costs for overlapping
insurance coverage maintained by Enrolled Parties will not be
reimbursable.  All change orders, except
deductive change orders for insurance costs, will be submitted net of
insurance, and labor rates will be appropriately reduced.

 

Each Enrolled Party (other
than the Contractor and its Affiliate Subcontractors) will be required to
identify the total cost of first dollar Workers’ Compensation, Commercial
General Liability and Umbrella/Excess Liability insurance that it proposes to
charge for its  proposed scope of Work,
regardless of the risk financing technique which that Enrolled Party employs
for its Workers’ Compensation and General Liability exposures, including but
not limited to insurance premiums, expected losses with any retention or
deductible amount, loss handling expenses and administrative expenses.  In calculating insurance costs, the Enrolled
Parties shall use the Workers’ Compensation, General Liability and
Umbrella/Excess Liability limits as described in the “Insurance
Required of Enrolled Parties” section herein if they were required
to provide the coverages and limits of liability for onsite Work.

 

If the Enrolled Party carries a deductible under any
of its policies, then the following may be requested by Owner:

 

·                  Three (3) years of loss history for all entities that
retain losses. Paid, outstanding and total incurred losses must be evidenced by
policy period.

·                  Three (3) years of payroll history for all entities

 

The Enrolled Parties will
complete and submit the Insurance Premium Worksheet, including the supporting
documents (copies of the policy declaration page and policy rate pages or
Deductible Agreement pages if on a large deductible program) to Owner.  The Enrolled Parties will warrant that all
insurance premium calculations have been correctly identified.

 

If Contractor has not yet
identified all of its Subcontractors or does not have the insurance cost for
its Subcontractors, Contractor must include the basis for its premium
estimate.  A separate Insurance Premium
Worksheet must be completed for each Enrolled Party and must be sent to  Owner.

 

If any Enrolled Party
does not provide Owner with information sufficient to allow verification of the
applicable insurance cost, Owner may independently calculate an appropriate
insurance cost based on undiscounted or “manual” rates.

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

Page
5 of 9

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Warranty
Statement:  The Enrolled Parties will provide and
warrant the accuracy of the information provided on the Insurance Premium
Worksheet and Enrollment Package, including the supporting documents (copies of
the policy declaration page and policy rate pages or Deductible Agreement pages
if on a large deductible program or a letter from the insurance carrier
evidencing the deductible rate and loss content rate) and/or any change order
forms and agree that Owner and/or the OCIP insurance companies may, but are not
required to, audit the Contractor’s and/or Subcontractors records to confirm
the accuracy for any and all allowable insurance credits.  The Enrolled Parties agree and warrant that
the Owner is entitled to and may collect additional insurance costs as may be
developed as a result of said audits and/or changes/change orders as may be agreed
to in connection with the Work.  The
Enrolled Parties which are signatories to the Agreement agree to make available
for review insurance records, policies, declaration pages of policies,
certificates of self-insurance and such other documents as may be reasonably
requested in connection with the insurances required to be provided in the
Agreement in order to respond appropriately to claims against Owner.  Such information shall only be made available
at the Enrolled Party’s home office.

 

Application For
Insurance:  The Enrolled Parties will complete an
Enrollment Application when requested by Owner as a condition to Owner
providing the insurance coverage described in the “Insurance
Provided by the Owner” section herein.  In addition, the Enrolled Parties will
cooperate with Owner regarding such application.  A Project Insurance Manual will be
distributed to the Enrolled Parties in accordance with this Exhibit.  This manual will describe the procedures to
be followed by the Enrolled Parties for enrolling in and complying with the
OCIP.  The Enrolled Parties will complete
the Enrollment Application and other such forms contained in the Enrollment
Package as applicable, as well as complete the monthly payroll reporting form
and follow the procedures as outlined in the Project Insurance Manual.  This payroll information shall only be used
for OCIP purposes and made available only to personnel administrating the
OCIP.  The Enrolled Parties will include
these insurance specifications in each of its contracts with Subcontractors
providing Work at the Site and will ensure that such Subcontractors receive the
Project Insurance Manual, enroll in the OCIP, and comply with the OCIP
procedures.

 

Cooperation: 
The Enrolled Parties will:

 

1.               Furnish to Owner, its insurance
representatives or the insurance company reasonable information and
documentation which the OCIP may require in connection with the issuance of any
policies, in such form and substance as Owner or its designee may require.

 

2.               Furnish to Owner, its insurance
representative or the insurance company, onsite payroll reports on the form as
required and described in the Project Insurance Manual by the 15th of the
following month for the prior month (including months with no payroll).

 

3.               Permit Owner, its insurance
representative and/or the insurance company to audit the Enrolled Parties’
books and records and provide documentation as may be required to assure
accuracy of those payroll reports.  The
Enrolled Parties agree that their failure to submit documents as required may
result in withholding progress payments until said payroll reports are received
by Owner or its designee.

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

Page
6 of 9

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

4.               Promptly comply with the reasonable requirements,
obligations and recommendations of Owner, its insurance representative or
insurance company so that the OCIP may be properly administered and so that the
insurance companies will continue to provide the coverage as specified in this Exhibit
under the OCIP.

 

5.               The Enrolled Parties will provide Owner and Owner’s
representative with reasonable information necessary for the issuance of said
policies and will maintain and make available to the insurance companies
payroll records and such other records relating to the Work as may be necessary
for the proper computation of the insurance premiums.

 

6.               The Enrolled Parties will cooperate with Owner with
regard to administration and operation of the OCIP.  The Enrolled Parties’ responsibilities will
include, but are not limited to: operations and insurance information;
inclusion of OCIP provisions in all applicable Subcontracts; notification to
Owner’s representative of all applicable subcontracts awarded; maintenance and
provision of monthly payroll records and such other records as necessary for
premium computation; compliance with applicable loss control (safety) and
claims reporting procedures; maintenance of an OSHA Log to be provided monthly to Owner and/or Owner’s
representative.

 

Insurance
Required of Enrolled Parties

 

The OCIP provides
coverage for Work at the Site only.

 

Insurance for the Work
performed by Enrolled Parties away from the Site include the following coverage
as further described below:

 

Workers’ Compensation and
Employer’s Liability Insurance

Commercial General
Liability Insurance

Commercial Automobile
Liability Insurance

 

The Enrolled
Parties will provide and maintain the types of insurance described below in a
company or companies legally authorized to transact insurance business in the
State of South Carolina.  All insurers will be rated at least A- VII in
the current A.M. Best ratings or must be otherwise acceptable to Owner.  The Enrolled Parties will maintain the
specified insurance coverage until all obligations under the Agreement are
satisfied but in no event later than the end of the Warranty Period.

 

Workers’
Compensation and Employer’s Liability: 
The
Enrolled Parties will maintain Statutory Workers’ Compensation insurance to
cover obligations imposed by federal and state statutes having jurisdiction
over its employees while engaged in the performance of the Work at locations
other than those described as the Site. This insurance will also cover any
Enrolled Parties’ employees working away from the Site and coming on the Site
after Substantial Completion and Subcontractors’ employees after each
Subcontractor has finally performed its contract.  The limits of Employer’s Liability are as
follows:

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

Page
7 of 9

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Workers’ Compensation
coverage will comply with the statutory limits of the State of South Carolina,
and will provide for Employers Liability insurance with limits as follows:

 

[**]
bodily injury by accident [**]

[**]
bodily injury by disease [**]

[**]
bodily injury by disease[**]

 

Commercial
General Liability:  The Enrolled Parties will maintain insurance for premises and operations
away from the Site of the Enrolled Parties (including products liability for
any product manufactured, assembled or otherwise worked upon away from the
Site) in a form providing coverage consistent with that of Commercial General
Liability insurance policy (“Occurrence Form”) 
for operations of the party required to furnish same, including hazards
of elevators, independent contractors, products and completed operations, with
contractual liability and personal advertising injury liability coverage for
claims arising out of the Work hereunder for personal injury, bodily injury and
property damage in policy or policies of insurance such that the total
available limits combined will be at least:

 

[**]

 

Any deductibles in place
will be the responsibility of the Enrolled Parties as respects to offsite
activities.

 

Commercial
Automobile Liability:  The Enrolled Parties will maintain insurance covering all  owned, hired, borrowed, leased, or non-owned
automobiles.  Such insurance will provide
coverage not less than that of the Commercial Automobile Liability policy in
limits not less than:

 

[**] for Bodily Injury
and Property Damage.

Contractual Liability, if
not provided in the policy form, is to be provided by endorsement.

 

Deductibles will be the
responsibility of Contractor with respect to offsite automobile activities.

 

Contractor’s
Equipment:  The Enrolled Parties are responsible for
their construction tools and equipment, including but not limited to
construction trailers and their contents, and temporary scaffolding, whether
owned, leased, rented, borrowed or used at the Site; and the Enrolled Parties
agree that Owner will not be responsible for any loss or damage to its tools and
equipment.  If insured, the Enrolled
Parties’ insurance policy covering tools and equipment will include a waiver of
subrogation in favor of the Owner.  If
uninsured, the Enrolled Parties will release the Owner for loss or damage to
their tools and equipment.

 

Additional Insureds: 
Each policy required (except Workers’ Compensation) will name as
additional insured the Owner,  the Owner’s
representatives, their respective parent companies, their subsidiaries, related
and affiliated companies of each and the officers, directors, agents, employees
and assigns of each.  General Liability
coverage maintained by Contractor and all Subcontractors shall contain an
additional insured endorsement pursuant to Section 16.3 of the

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

Page
8 of 9

 

	
  Execution Version

  	
  Confidential Trade Secret
  Information—Subject to Restricted Procedures

  

 

Agreement. 
Products and Completed Operations coverage shall be maintained for [**]
after Substantial Completion.

 

Waiver Of Subrogation: The Enrolled Parities and their respective insurers
providing the required coverage as indicated in Workers’ Compensation and
Commercial General Liability, Umbrella/Excess Liability or any required
coverages, will waive all rights of subrogation against the Owner, its
Affiliates, and their agents, officials, and employees.

 

Each Enrolled Party will
pay all insurance premiums for such insurance, including any charges for
required waivers of subrogation or the endorsement of additional insureds.

 

Primary And
Non-Contributory:  Liability and Workers’ Compensation Insurance
coverage for Work AWAY FROM THE SITE required of the Enrolled Parties is
primary and non-contributory.

 

Certificates of
Insurance:  The Enrolled Parties and Excluded Parties will provide certificates of
insurance to Owner as evidence that policies specified in this section
providing the required coverage, conditions, and limits are in full force and
effect.

 

Notice of
Cancellation: All
insurance policies and certificates of insurance will include a requirement
providing for thirty (30) days prior written notice to Owner of any
cancellation or reduction of coverage. 
If any such notice is given, Owner will have the right to require that a
substitute policy be obtained prior to said cancellation with appropriate
evidence thereof at the discretion of Owner. 
The Enrolled Parties and Excluded Parties will immediately notify Owner
and will cease operations on the occurrence of any such cancellation or
reduction and will not resume operations until the required insurance is in
force and new certificates of insurance have been filed with Owner.

 

Insurance Requirements of Excluded Parties

 

Excluded Parties
performing Work will obtain and maintain, and will  require each of their excluded Subcontractors
to obtain and maintain, the insurance coverage specified in Article 16 of the
Agreement, unless such coverage is waived by Contractor consistent with its
practices.  Should
Contractor waive such insurance requirements of any Subcontractor, Contractor
assumes the responsibility for any loss to Owner which would have been covered by
such required insurance coverages had the Subcontractor maintained such
required coverages.

 

“[**]” in this Exhibit 10.01
indicates material that has been omitted pursuant to a request for confidential
treatment and filed separately with the Securities and Exchange Commission.

 

Page
9 of 9

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

EXHIBIT V

Limited Agency Agreement

 

THIS LIMITED AGENCY AGREEMENT (“Agreement”), dated as
of                     , is entered into
by and between SOUTH CAROLINA PUBLIC SERVICE AUTHORITY (“Principal”), a public
power system owned by the State of South Carolina, and SOUTH CAROLINA ELECTRIC &
GAS COMPANY (“Agent”), a corporation duly organized under the laws of the State
of South Carolina, (Principal and Agent may be referred to individually as a “Party”
and collectively as the “Parties”).

 

WHEREAS, Principal and Agent wish to collaborate
jointly in the financing, design, construction, operation, and decommissioning
of a new advanced design light water nuclear-powered electric generating
facility (the “Project”);

 

WHEREAS, in connection with the Project, the
Parties intend to enter into a Permanent Design and Construction Agreement and
a Permanent Operating and Decommissioning Agreement that shall set forth the
terms and conditions that shall govern the Parties’ participation in the
Project; and

 

WHEREAS, until such time as the Permanent Design
and Construction Agreement and Permanent Operating and Decommissioning
Agreement are negotiated, executed and delivered by the Parties, the rights and
obligations of the Parties to each other in connection with the Project shall
be governed by that certain Bridge Agreement between Principal and Agent, dated
October 30, 2006, and as further amended from time to time (the “Bridge Agreement”);

 

WHEREAS, Sections 6.1 and 8.3 of the Bridge
Agreement contemplate that the Parties may enter into one or more limited
agency agreements in connection with certain Project-related third party
agreements, including but not limited to the Engineering, Procurement and
Construction Agreement (the “EPC Contract”) for up to two AP1000 nuclear power
plant with Westinghouse Electric Company LLC and Stone & Webster, Inc.
(collectively, “Westinghouse”), attached hereto as Exhibit A; and

 

WHEREAS, Principal and Agent desire to enter into
such a limited agency agreement and Principal wishes to appoint Agent to act as
agent on Principal’s behalf in connection with the negotiation, execution and
performance of the EPC Contract, subject to certain limitations set forth
herein, and Agent is willing to accept such limited agency appointment;

 

NOW, THEREFORE, in consideration of the mutual agreements herein
contained and other good and valuable consideration, the receipt and adequacy
of which is hereby acknowledged, the parties hereto agree as follows:

 

1.                                      Limited Agency Appointment. 
Pursuant to the terms of this Agreement and subject to the limitations
set forth in Paragraph 2 of this Agreement, Principal hereby appoints and
grants a limited agency authorization to Agent, and Agent hereby accepts such
limited agency appointment and agrees to act on behalf of the Principal, with
regard to the negotiation, execution and performance of the EPC Contract.

 

“[**]” in this Exhibit 10.01 indicates material that
has been omitted pursuant to a request for confidential treatment and filed
separately with the Securities and Exchange Commission.

 

1 of 8

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

2.                                      Limitations on Agency Appointment. 
Agent’s authorization to act on behalf of Principal with respect to the
EPC Contract shall be limited to the negotiation, execution and performance of
the obligations of the Owner (as such term is defined in the EPC Contract) and
enforcement of the rights of such Owner under the EPC Contract; provided, however, that
Agent shall not, without the prior written consent of Principal, which consent
may be withheld in Principal’s sole discretion, do or permit to be done any of
the following:

 

	
   

  	
  Agency Limitation

  	
  EPC Contract Section Reference

  
	
   

  	
   

  	
   

  
	
  (a)

  	
  Agree
  upon a definitive contract price

  	
  N/A

  
	
   

  	
   

  	
   

  
	
  (b)

  	
  Execute
  the EPC Contract

  	
  N/A

  
	
   

  	
   

  	
   

  
	
  (c)

  	
  Issue
  a Full Notice to Proceed

  	
  3.2(b)

  
	
   

  	
   

  	
   

  
	
  (d)

  	
  Terminate
  Second Unit

  	
  3.3(b)

  
	
   

  	
   

  	
   

  
	
  (e)

  	
  With
  respect to any Major Subcontract under Section 3.7, Agent shall not (i) participate
  in any claim, action or proceeding; (ii) cure any default; (iii) consent to
  termination, assignment or modification; or (iv) assume or enter into any
  Major Subcontract in the event of Contractor’s bankruptcy or insolvency

  	
  3.7

  
	
   

  	
   

  	
   

  
	
  (f)

  	
  Substantial
  Completion

  	
  8.2

  
	
   

  	
   

  	
   

  
	
  (g)

  	
  Approve
  payment of Final Payment

  	
  8.3

  
	
   

  	
   

  	
   

  
	
  (h)

  	
  Approve
  substitute form of security or lower bond amount for Stone & Webster
  and/or Westinghouse

  	
  8.6(b) and 8.6(c)

  
	
   

  	
   

  	
   

  
	
  (i)

  	
  Agree
  to any Change Order that increases the overall costs incurred under the EPC
  Contract by $1M or more, or along with all prior Change Orders issued under
  the EPC extends the Project Schedule for 3 months or more beyond the Substantial
  Completion Date.

  	
  9.2, 9.4

  
	
   

  	
   

  	
   

  
	
  (j)

  	
  Suspend
  the EPC Contract for Owner’s Convenience

  	
  22.1

  
	
   

  	
   

  	
   

  
	
  (k)

  	
  Terminate
  the EPC Contract for Cause

  	
  22.2

  
	
   

  	
   

  	
   

  
	
  (l)

  	
  Elect
  to take over the Project upon Owner’s Termination for Cause

  	
  22.2(c)

  

 

“[**]” in this Exhibit 10.01 indicates material that
has been omitted pursuant to a request for confidential treatment and filed
separately with the Securities and Exchange Commission.

 

2 of 8

 

	
  Execution Version

  	
  Confidential Trade
  Secret Information—Subject to Restricted Procedures

  

 

	
  (m)

  	
  Terminate
  the EPC Contract for Owner’s Convenience

  	
  22.3

  
	
   

  	
   

  	
   

  
	
  (n)

  	
  Terminate
  for failure to obtain regulatory approvals

  	
  22.4

  
	
   

  	
   

  	
   

  
	
  (o)

  	
  File
  a Claim, initiate the dispute resolution process, or initiate or defend a
  lawsuit involving a third party in connection with the EPC Contract

  	
  27

  
	
   

  	
   

  	
   

  
	
  (p)

  	
  Consent
  to entry of any judgment or award in a disputed matter in connection with the
  EPC Contract or enter into any settlement or compromise of a dispute in
  connection with the EPC Contract

  	
  N/A

  
	
   

  	
   

  	
   

  
	
  (q)

  	
  Consent
  to an assignment of the EPC Contract

  	
  29

  
	
   

  	
   

  	
   

  
	
  (r)

  	
  Materially
  amend, modify or supplement the EPC Contract

  	
  31

  

 

3.                                      Term and Termination.

 

(a)                                  This Agreement shall remain in full force
and effect beginning on the first date specified above and continuing
thereafter until February 1, 2019, unless renewed by the Parties in writing on
a year-to-year basis no less than thirty (30) days prior to the expiration of
the initial term or any subsequent renewal term, or upon the occurrence of one
of the following: (i) the Project begins commercial operations; (ii) the
Principal or Agent terminate their participation in the Project, with or
without cause; provided, however,
that each Party must provide to the other Party written notice at least sixty
(60) days prior to any such abandonment of the Project and, in the event that
the Project is abandoned by one Party but not the other, the abandoning Party
shall use commercially reasonable efforts to facilitate the transfer of its
obligations hereunder to the other Party or to any other entity designated or
appointed by the other Party to assume the abandoning Party’s obligations
hereunder; or (iii) by written mutual agreement of the Parties.

 

(b)                                 The rights and obligations of the Parties
for indemnification for acts or omissions occurring prior to the termination
shall survive any termination of this Agreement.

 

(c)                                  Agent’s obligations under any third party
agreements entered into prior to the termination of this Agreement would
survive such termination and remain binding on Agent.

 

“[**]” in this Exhibit 10.01 indicates material that
has been omitted pursuant to a request for confidential treatment and filed
separately with the Securities and Exchange Commission.

 

3 of 8

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

4.                                      Representations and Warranties. 
Each Party represents and warrants to the other Party that, as of the
date first stated above:

 

(a)                                  It is duly organized, validly existing
and in good standing under the applicable laws of the jurisdiction of its
organization and is qualified to do business in all jurisdictions necessary to
perform this Agreement;

 

(b)                                 It has the power and authority to execute
and deliver this Agreement and to perform its obligations under this Agreement
and has taken all necessary corporate and/or other actions to authorize such
execution, delivery and performance;

 

(c)                                  Its execution and delivery and performance
of its obligations under this Agreement do not violate or conflict with: (i) any
laws applicable to it; (ii) any provision of its charter or by-laws or
comparable constituent documents Agreement; (iii) any order or judgment of any
court of governmental authority applicable to it or any of its assets; or (iv) any
contractual restriction binding on or affecting it or any of its assets;

 

(d)                                 This Agreement has been duly executed and
delivered by the Party and constitutes its legal, valid, and binding
obligation, enforceable against it in accordance with its terms, subject to
applicable bankruptcy, reorganization, insolvency, moratorium or similar laws
affecting creditors’ rights generally and subject, as to enforceability, to
equitable principles of general application (regardless of whether enforcement
is sought in a proceeding in equity or at law); and

 

(e)                                  Except as otherwise permitted herein, it
has neither initiated nor received written notice of any pending action,
proceeding, or investigation, nor to its knowledge is any such action,
proceeding, or investigation threatened (or any basis therefore known to it),
which questions the validity of this Agreement, or which would materially or
adversely affect its rights or obligations under this Agreement.

 

5.                                      Expenses and Audit Rights. 
Expenses of the Parties and audits rights in connection with this
Agreement (including without limitation, funding required under the EPC
Contract) shall be handled in accordance with Article V of the Bridge
Agreement.

 

6.                                      Access to Information; Reporting
Obligations.

 

(a)                                  No less frequently than monthly (or more
frequently as circumstances reasonably warrant), Agent, to the best of its
knowledge, shall inform Principal of the status of the Project, including but
not limited to any activities or decisions that the Agent has made or expects
to make with regard to the EPC Contract. 
Further, as provided in Section 4.2(a) of the Bridge Agreement, Agent
and Principal shall hold periodic meetings with (1) the Executive Steering
Committee at the request of either member of the Executive Steering Committee
and (2) other Project employees and contractors as either Party deems
appropriate or at the request of either member of the Executive Steering
Committee.

 

(b)                                 Agent will make available to Principal
all documentation related to the Project, which can be done by providing
original documents, providing copies of documents or allowing

 

“[**]” in this Exhibit 10.01 indicates material that
has been omitted pursuant to a request for confidential treatment and filed
separately with the Securities and Exchange Commission.

 

4 of 8

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

Principal’s representatives
to review the relevant files and business records as kept in the ordinary
course of business at the Agent’s offices or with another representative of the
Agent.  Agent shall also make its
personnel available to Principal for consultation.

 

(c)                                  Principal shall provide Agent access to
information in its possession reasonably necessary for Agent to perform its
obligations under this Agreement; provided, however, that Principal may restrict access to information
to the extent that it is subject to third party confidentiality restrictions
and Principal has been unsuccessful in having such restrictions waived.

 

7.                                      Indemnity.

 

(a)                                  Agent agrees to indemnify, defend and
hold harmless the Principal, its affiliates and any of their members, officers,
directors and employees, agents and representatives against and in respect of
all claims, liabilities, obligations, judgments, liens, injunctions, charges,
orders, decrees, rulings, damages, dues, assessments, taxes, losses, fines,
penalties, damages, expenses, fees, costs and amounts paid in settlement
(including reasonable attorneys’ fees, expert witness fees and disbursements in
connection with investigating, defending or settling any action or threatened
action), arising out of any claim, complaint, demand, cause of action, action,
suit or other proceeding asserted or initiated or otherwise existing in respect
of any matter (collectively, the “Losses”) arising out of Agent’s activities
undertaken on behalf of Principal under this Agreement; provided
that Principal shall be liable, and shall not be indemnified by Agent, for any
Losses directly resulting from the untruth, inaccuracy or incompleteness of any
representation or warranty made expressly by Principal in this Agreement, and
Principal shall indemnify Agent, its affiliates and any of their officers,
directors and employees, agents and representatives, for Losses that result
from any such breach by Principal.

 

(b)                                 Principal agrees to indemnify, defend and
hold harmless the Agent, its affiliates and any of their members, officers,
directors and employees, agents and representatives against and in respect of
all claims, liabilities, obligations, judgments, liens, injunctions, charges,
orders, decrees, rulings, damages, dues, assessments, taxes, losses, fines, penalties,
damages, expenses, fees, costs and amounts paid in settlement (including
reasonable attorneys’ fees, expert witness fees and disbursements in connection
with investigating, defending or settling any action or threatened action),
arising out of any claim, complaint, demand, cause of action, action, suit or
other proceeding asserted or initiated or otherwise existing in respect of any
matter (collectively, the “Losses”) arising out of Principal’s activities under
this Agreement; provided that Agent shall be
liable, and shall not be indemnified by Principal, for any Losses directly
resulting from the untruth, inaccuracy or incompleteness of any representation
or warranty made expressly by Agent in this Agreement, and Agent shall
indemnify Principal, its affiliates and any of their officers, directors and
employees, agents and representatives, for Losses that result from any such
breach by Agent.

 

8.                                      Specific Performance. 
Each of the Parties acknowledges and agrees that the other Party would
be damaged irreparably in the event any of the provisions of this Agreement are
not performed in accordance with their specific terms or otherwise are
breached.  Accordingly, each of the
Parties agrees that the other Party shall be entitled to an injunction or
injunctions to prevent breaches of the provisions of this Agreement and to
enforce specifically this Agreement

 

“[**]” in this Exhibit 10.01 indicates material that
has been omitted pursuant to a request for confidential treatment and filed
separately with the Securities and Exchange Commission.

 

5 of 8

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

and the terms and provisions hereof in any action instituted in any court
of the United States or any state thereof having jurisdiction over the Parties
and the matter in addition to any other remedy to which it may be entitled, at
law or in equity.

 

9.                                      Waivers.  No waiver by
either Principal or Agent of the performance of any obligation under this
Agreement, or with respect to any default or any other matter arising in
connection with this Agreement, shall be deemed a waiver with respect to any
subsequent performance, default or matter, whether of a like or different
character.

 

10.                                Notices.  Any notice,
demand or request relative to this Agreement to be given to any of the
Principal, or the Agent shall be in writing, and shall be delivered by U. S.
mail, facsimile or hand delivery to the authorized representative of the Principal
or Agent at the address specified below, or a successor designated in any
notice given pursuant to this paragraph.

 

If to the Agent:

 

South Carolina Electric & Gas Company

Attention: President

Mail Code 190

Columbia, SC 29218

Facsimile: (803) 217-9336

 

If to the Principal:

 

South Carolina Public Service Authority

Attention:
President and Chief Executive Officer

One
Riverwood Drive

Moncks Corner, SC 29461

Facsimile:
(843) 761-7037

 

11.                                Miscellaneous.

 

(a)                                  Entire Agreement. 
This Agreement embodies the entire understanding and agreement among the
Parties pertaining to the subject matter hereof and supersedes any and all
prior negotiations, understandings or agreements with respect thereto.

 

(b)                                 Counterparts. 
This Agreement may be executed in any number of counterparts, each of
which shall constitute an original, but all of which, when taken together,
shall constitute one and the same document.

 

(c)                                  Assignment.  No party to
this Agreement shall assign any of its rights or obligations under this
Agreement without first receiving the written consent of all other parties,
which consent shall not be unreasonably withheld.

 

(d)                                 No Third Party Beneficiaries. 
This Agreement is binding upon and intended solely for the benefit of
the parties hereto and their respective successors and permitted assigns and,
unless expressly stated herein, is not intended to and shall not confer any
rights or benefits to any third party (other than successors and permitted
assigns) not a signatory hereto.

 

“[**]” in this Exhibit 10.01 indicates material that
has been omitted pursuant to a request for confidential treatment and filed
separately with the Securities and Exchange Commission.

 

6 of 8

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

(e)                                  Amendment.  Neither this
Agreement nor any terms hereof may be changed, waived, discharged or terminated
except by an instrument in writing signed by each of the parties hereto.

 

(f)                                    Headings.  The headings
in this Agreement are for convenience of reference only and shall not be
defined or limit the terms hereof.

 

(g)                                 Governing Law. 
This Agreement and all questions with respect to the rights and
obligations of the Parties and the construction, enforcement and interpretation
hereof shall be governed by the laws of the State of South Carolina, without
reference to the choice of law principles that require application of the laws
of a different jurisdiction.

 

(h)                                 Jurisdiction. 
Any dispute arising from this Agreement shall be subject to the
jurisdiction of the courts in South Carolina.

 

(i)                                     Severability. 
Any provision of this Agreement this prohibited or unenforceable in any
jurisdiction, as to that jurisdiction, shall be ineffective to the extent of
that prohibition or unenforceability without invalidating the remaining
provisions hereof or affecting the validity or enforceability of that provision
in any other jurisdiction.

 

(j)                                     Good Faith Covenant. 
The Parties agree that their actions and dealings with each other shall
be subject to an express covenant of good faith and fair dealing and that each
Party shall act in a commercially reasonable manner in fulfilling its
obligations under this Agreement.

 

(k)                                  Confidentiality. 
The Parties acknowledge and agree that this Agreement is subject to the
Confidentiality Agreement between the Parties dated as of June 8, 2006.

 

“[**]” in this Exhibit 10.01 indicates material that
has been omitted pursuant to a request for confidential treatment and filed
separately with the Securities and Exchange Commission.

 

7 of 8

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

IN WITNESS
WHEREOF, the Parties hereto, each acting through its respective duly authorized
representative, have executed this Agreement, made as of the date first above
written.

 

 

	
   

  	
  SOUTH CAROLINA PUBLIC SERVICE AUTHORITY

  
	
   

  	
   

  
	
   

  	
  By:

  
	
   

  	
  Title:

  
	
   

  	
   

  
	
   

  	
   

  
	
   

  	
  SOUTH CAROLINA ELECTRIC & GAS COMPANY

  
	
   

  	
   

  
	
   

  	
  By:

  
	
   

  	
  Title:

  

 

“[**]” in this Exhibit 10.01 indicates material that
has been omitted pursuant to a request for confidential treatment and filed
separately with the Securities and Exchange Commission.

 

8 of 8

 

	
  Execution Version

  	
  Confidential
  Trade Secret Information—Subject to Restricted Procedures

  

 

EXHIBIT W

Extended Equipment Warranty Special Terms

 

Each Extended Equipment
Warranty Period will have a term no greater than [**].

 

All other terms of any
such Extended Equipment Warranty will be stated in this Exhibit. Contractor shall provide information as [**] such extended
warranties and any special terms applicable to such extended warranties (each,
an “Extended Equipment Warranty”) once identified by the Subcontractor for the
Equipment. Owner shall have the right to exercise its option for any such
Extended Equipment Warranty within the time period specified for the exercise
of the option by the Equipment vendor.

 

The Equipment that
warrants an option for an Extended Warranty from the Subcontractors is
identified below:

 

[**]

 

“[**]” in this Exhibit 10.01 indicates material that
has been omitted pursuant to a request for confidential treatment and filed
separately with the Securities and Exchange Commission.

 

1 of 1

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00160-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00160-of-00352.parquet"}]]