Document:

Exhibit 10.39

 

FORM OF

 

SHIPBUILDING CONTRACT

 

FOR

 

CONSTRUCTION OF ONE 3800 DWT PRODUCT OIL TANKER

 

(HULL NO. DN-3800-   )

 

BETWEEN

 

 

 

as BUYER

 

and

FUJIAN SOUTHEAST SHIPYARD

 

as SELLER

 

 

CONTENTS

 

	
  ARTICLE 1 -

  	
   

  	
  DESCRIPTION AND CLASS

  	
   

  	
  4

  
	
  ARTICLE 2 -

  	
   

  	
  CONTRACT PRICE & TERMS OF
  PAYMENT

  	
   

  	
  6

  
	
  ARTICLE 3 -

  	
   

  	
  ADJUSTIVIENT.OF THE CONTRACT
  PRICE

  	
   

  	
  9

  
	
  ARTICLE 4 -

  	
   

  	
  APPROVAL OF PLANS AND DRAWINGS -
  SUPERVISION AND INSPECTION

  	
   

  	
  12

  
	
  ARTICLE 5 -

  	
   

  	
  MODIFICATION, CHANGES AND EXTRAS

  	
   

  	
  14

  
	
  ARTICLE 6 -

  	
   

  	
  TRIALS

  	
   

  	
  16

  
	
  ARTICLE 7 -

  	
   

  	
  DELIVERY

  	
   

  	
  18

  
	
  ARTICLE 8 -

  	
   

  	
  DELAYS & EXTENSION OF E FOR
  DELIVERY

  	
   

  	
  21

  
	
  ARTICLE 9 -

  	
   

  	
  WARRANTY OF QUALITY

  	
   

  	
  23

  
	
  ARTICLE 10 -

  	
   

  	
  CANCELLATION, REJECTION AND
  RESCISSION BY THE .BUYER

  	
   

  	
  26

  
	
  ARTICLE 11 -

  	
   

  	
  BUYER’S DEFAULT

  	
   

  	
  26

  
	
  ARTICLE 12 -

  	
   

  	
  INSURANCE

  	
   

  	
  28

  
	
  ARTICLE 13 -

  	
   

  	
  DISPUTES AND ARBITRATION

  	
   

  	
  30

  
	
  ARTICLE 14 -

  	
   

  	
  RIGHT OF ASSIGNMENT

  	
   

  	
  31

  
	
  ARTICLE 15 -

  	
   

  	
  TAXES AND DUTIES

  	
   

  	
  32

  
	
  ARTICLE 16 -

  	
   

  	
  PATENTS, TRADEMARKS AND
  COPYRIGHT,

  	
   

  	
  32

  
	
  ARTICLE 17 -

  	
   

  	
  NOTICES

  	
   

  	
  32

  
	
  ARTICLE 18 -

  	
   

  	
  EFFECTIVE DATE OF CONTRACT

  	
   

  	
  33

  
	
  ARTICLE 19 -

  	
   

  	
  INTERPRETATION

  	
   

  	
  33

  

 

2

 

SHIPBUILDING CONTRACT

FOR

CONSTRUCTION OF ONE 3800DWT PRODUCT OIL TANKER

(HULL NO. DN-3800-   )

 

This CONTRACT,
entered into this day 25 May 2007, by and between                           ,
a corporation organized and existing under the Laws of Liberia, having its
registered office at 80, Broad Street, Monrovia, Liberia or its
nominee, thereinafter called the “BUYER”) on one part; and Fujian Southeast
Shipyard, a corporation organized and existing under the Laws of the People’s
Republic of China, having its registered office at 7# Jianshe Road, Economic
Technical Development Zone of Fuzhou, Fujian Province, the People’s Republic of
China ( hereinafter called the “SELLER” or the “SELLER”).

 

WITNESSETH

 

In
consideration of the mutual covenants contained herein, the SELLER agrees to
design., build, launch, equip and complete at the SELLER’s Shipyard and to sell
and deliver to the BUYER after completion and successful trial specified in
this Contract one (1) 3800DWT product tanker as more fully described in Article
1 hereof (hereinafter called the “VESSEL”), to be registered at the option of
the -BUYER under the Panamanian (or equivalent convenient) flag which may be
chosen by the BUYER and agreed by the SELLER and the BUYER agrees to purchase
and take delivery of the aforesaid VESSEL from the SELLER and to pay for the
same in accordance with the terms and conditions hereinafter set forth.

 

3

 

ARTICLE 1 - DESCRIPTION AND CLASS

 

1.                                       DESCRIPTION

 

The VESSEL
shall be a 3800 metric tons deadweight oil product tanker, at design summer
draught of 5.5 meters of the class described below. The VESSEL shall have the
SELLER’s Hull No.DN-3800-    and shall be constructed, equipped and
completed as described in and in accordance with the terms of this Contract and
the following documentation:

 

(1)                                  Technical
Specification (Drawing No. B1/2-0001),

 

(2)                                  General
Arrangement - (Drawing No. B1/2-0102),

 

(3)                                  Makers
list - (Drawing No. B1/2-0002),

 

(4)                                  Midship
Section - (Drawing No. H1/2-1101),

 

it being
expressly agreed that the following will be also included:

 

(a)                                  All
alterations as agreed up to the date of signing this Contract for the ten (10)
vessels DN-3500-1. DN-3500-2, DN-3500-3, DN-3500-4 DN3500-5, DN-3500-6,
DN-3500-7, DN-3500-8, DN-3500-9, and DN3500-10 either requested by Class or
agreed between each respective buyer and the SELLER.

 

(b)                                 Any
solutions to pending or unresolved problems agreed between each respective
Buyer and Seller and as implemented on for the ten (10) vessels DN-3500-1,
DN-3500-2, DN-3500-3, DN-3500-4 DN-3500-5, DN-3500-6, DN-3500-7, DN-3500-8,
DN-3500-9, and DN-3500-10 will be implemented on this project.

 

(c)                                  Any
change to the specific Makers or equipments used for the ten (10) vessels
..DN-3500-1, DN-3500-2, DN-3500-3, DN-3500-4 DN-3500-5, DN-3500-6, DN-3500-7,
DN-3500-8, DN-3500-9, and DN-3500-10 shall be subject to negotiation and the
mutual agreement of the parties.

 

Attached
hereto and signed by each of the parties to this Contract (hereinafter
collectively called the “Specifications”), making an integral part hereof

 

2.                                       CLASS
AND RULES

 

The VESSEL
including its machinery, equipment and out fittings, shall be constructed in
accordance with and shall comply with the rules and regulations of and under
the supervision of American Bureau of Shipping (ABS) (hereinafter called the “Classification
Society”) and distinguished in record by the symbols:  +Al OIL CARRIER (E) ESP, FP.<60°C, +ACC,
+AMS

 

The
requirements of the authorities and other regulatory bodies as fully described
in the Specifications including that of the Classification Society are to
include any rules or circulars thereof which have been issued and become
effective by the dale of signing this Contract.

 

The SELLER
shall arrange with the Classification Society to assign a representative or
representatives (hereinafter called the “Classification Surveyor”) to the
SELLER’s Shipyard for supervision of the construction of the VESSEL.

 

All fees and
charges incidental to classification and to compliance with all the rules,
regulations and requirements of this Contract and as described in the
Specifications issued and become

 

4

 

effective up
to the date of signing this Contract as well as royalties, if any, payable on
account of the construction of the VESSEL shall be for the account of the
SELLER, except as otherwise provided and agreed herein. The key plans,
materials and workmanship entering into the construction of the VESSEL and the
VESSEL itself shall at all times be subject to inspections and tests in
accordance with the rules and regulations of the Classification Society and
regulatory bodies, which males and regulations as described in detail in page
14;15 and 16 of the Specifications are all accepted by the SELLER.

 

Decisions of
the Classification Society as to compliance or non-compliance with
Classification rules and regulations shall be final and binding upon the
parties hereto.

 

3.                                       PRINCIPAL
PARTICULARS AND DIMENSIONS OF THE VESSEL

 

	
  (a)

  	
  Hull

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  Length overall

  	
   

  	
  abt.

  	
   

  	
  90.00m

  
	
   

  	
  Length between
  perpendiculars

  	
   

  	
  abt.

  	
   

  	
  85.00m

  
	
   

  	
  Breadth, moulded

  	
   

  	
  abt.

  	
   

  	
  15.60m

  
	
   

  	
  Depth, moulded

  	
   

  	
  abt.

  	
   

  	
  7.80m

  
	
   

  	
  Designed Summer
  Draught,

  	
   

  	
  abt.

  	
   

  	
  5.50m

  
	
   

  	
  Scantling Draught

  	
   

  	
  abt.

  	
   

  	
  6.00m

  
	
   

  	
   

  	
   

  	
   

  	
   

  	
   

  
	
  (b)

  	
  Propelling
  Machinery

  	
   

  	
   

  	
   

  	
   

  
	
   

  	
  The VESSEL shall
  be equipped, in accordance with the Specifications, with one (1) set of WARTSILA 8L26 Main
  Engine.

  

 

4.                                       GUARANTEED
SPEED

 

The SELLER
guarantees that the trial speed at design draft (5.5m) at Maximum Continuous
Output of the main engine (MCR), with clean bottom in calm and deep sea under
heaufort scale of 2 or around is not to be less than 12.5 knots.

 

The speed
shall be corrected for wind speed and shallow water effect. The correction
method of the speed shall be as specified in the Specifications.

 

5.                                       GUARANTEED
DEADWEIGHT

 

The SELLER
guarantees that the VESSEL is to have a deadweight of not less than 3800 metric
tons at the summer design draught moulded of 5.50 meters in sea water 1.025
specific gravity.

 

The term, “Deadweight”,
as used in this Contract, shall be as defined in the Specification.

 

The actual
deadweight of the VESSEL expressed in metric tons shall he based on
calculations made by the SELLER and checked by the BUYER, and all measurements
necessary for such calculations shall be performed in the presence of the BUYER’s
supervisor(s) or the party authorized by the BUYER and the Classification
Society Surveyor.

 

Should there
he any dispute between the SELLER and the BUYER in such calculations and/or .measurements,
the decision of the Classification Society agreed by both parties shall he
final.

 

6.                                       SUBCONTRACTING

 

The SELLER
may, at its sole discretion and responsibility, subcontract any portion of the
construction work of the VESSEL to experienced subcontractors, any
subcontracting of main hull structure or superstructures shall require the
prior written approval of the BUYER and the Classification Society before work
commences. However delivery and final assembly into the

 

5

 

VESSEL of any
such work subcontracted shall be at the SELLER’S Shipyard. The SELLER shall
always fully remain responsible for such subcontracted work. The SELLER. shall
remain responsible for compliance with the obligations of this Contract as if
there had been no sub-contracting.

 

In its
contracts with its subcontractors and suppliers, the SELLER shall always ensure
reasonable time margins so as to avoid delays in the progress of the
construction of the VESSEL. Hull blocks to be excluded from subcontracting.

 

7.                                       REGISTRATION

 

The VESSEL
shall he registered by the BUYER at its own cost and expenses under the laws of
Panama (or equivalent convenient) the time of delivery and acceptance thereof
flying Panamanian (or equivalent convenient ) flag. The cost and expenses and
other relative cost involving applying and inspection for statutory surveys
will be borne by the Buyer.

 

The SELLER
warrants that the VESSEL shall upon delivery in construction and performance aspect
be acceptable for registration under the laws of Panama in force at the time of signing the Contract.

 

ARTICLE 2 - CONTRACT PRICE & TERMS OF PAYMENT

 

1.                                       CONTRACT
PRICE

 

The agreed
purchase price of the VESSEL is United States Dollars 7,890,000.00 (in words:
United States Dollars seven million eight hundred and ninety thousand Only);
(hereinafter called the “Contract Price”) net receivable by the SELLER. which
is exclusive of the cost for the BUYER’s Supplies as provided in Article 5
hereof. Therefore the
contract Price is a fixed
price  and shall not be subject to any upward or downward
adjustment except only in accordance with the provisions of Articles 3,5 and 6
of this contract.

 

2.                                       CURRENCY

 

Any and all
payments by the BUYER to the SELLER under this Contract shall he made in United
States Dollars.

 

3.                                       TERMS
OF PAYMENT

 

The Contract
Price shall be paid by the BUYER to the SELLER in installments as follows:

 

(a)                                  1st Installment:

 

The sum of
United States Dollars 755,000.00 (United States Dollars seven hundred fifty
five thousand only), shall become due and payable and be paid by the BUYER
within five (5) New York banking days after this Contract has been signed and
the Refund Guarantee referred to in paragraph 7 of this Article has been issued
and delivered to the BUYER:

 

(b)                                 2nd
Installment:

 

The sum of
United States Dollars 1,132,500.00 (United States Dollars one million and one
hundred thirty two thousand and five hundred only), shall become due and
payable and be paid within live (5) New York banking days after the cutting of
the first steel plate of the VESSEL in the SELLER’s workshop has occurred
accompanied by a copy of the

 

6

 

written
confirmation issued by the Classification Society to the effect that the
cutting of the first steel plate has been carried out.

 

The SELLER shall give a
telex, telefax or letter notice to the BUYER stating that the 1st steel plate
has been cut in its workshop and demand for payment of this installment.

 

(c)                                  3rd
Installment;

 

The sum of United States
Dollars 1,132,500.00 (United States Dollars one million and one hundred thirty
two thousand and five hundred only), shall become due and payable and shall be
paid within five (5) New York banking days after keel-laying of the first
section of the VESSEL. The keel-laying shall be notified by the SELLER with a
telex, telefax or letter notice to the BUYER stating that the said keel-laying
has been carried out accompanied by a copy of the written confirmation issued
by Classification Society to the effect that the keel-laying has been carried
out. The SELLER shall send to the. BUYER a telex or telefax demand for payment
of this installment.

 

(d)                                 4th
Installment:

 

The sum of United States
Dollars 1,132,500.00 (United States Dollars one million and one hundred thirty
two thousand and five hundred only), shall become due and payable and shall be
paid within five (5) New York banking days after successful launching of the
VESSEL. The launching of the VESSEL shall be notified by the SELLER with a
telex, telefax or letter notice to the BUYER stating that the launching of the
VESSEL has been successfully carried out. The SELLER shall send to the BUYER a
telex or telefax demand for payment of this installment.

 

(e)                                  5th
Installment (payment upon Delivery to and Acceptance by the BUYER of the
VESSEL):

 

The sum of United States
Dollars 3,737,500.00 (United States Dollars three million and seven hundred
thirty seven thousand and five hundred Only), plus any increase or minus any
decrease due to the modifications of the Specification and/or the adjustments
of the Contract Price hereunder in accordance with the provisions of the
relevant Articles hereof, shall become due and payable and be paid by the BUYER
to the SELLER concurrently with delivery to and acceptance by the BUYER of the
VESSEL and upon the signing of the Protocol of Delivery and Acceptance by both
parties. The SELLER shall send to the BUYER a telex or telefax demand for this
installment ten (10) days prior to the scheduled date of delivery of the
VESSEL.

 

4.                                       METHOD
OF PAYMENT

 

(a)                                  1st
Installment

 

The BUYER
shall remit the amount of this installment in accordance with Article 2,
Paragraph 3 (a) by telegraphic transfer to XXXXXXXXXXN Bank, xxxx Branch. the
People’s Republic of China as receiving bank nominated by the SELLER, for
credit to the account of XXXXXXXXXXXXXXXXXX
,Account No xxxxxxxxxxxxxx with direct SWIFT advice from the remitting
bank to xxxxxxxxxxxxxxx Bank, xxxx Branch.

 

(b)                                 2nd
Installment

 

The BUYER
shall remit the amount of this installment in accordance with Article 2,
Paragraph 3(b) by telegraphic transfer to xxxxxxxx Bank, xxxx Branch, the
People’s Republic of China as receiving hank nominated by the SELLER, for
credit to the account

 

7

 

of
xxxxxxxxxxxxxxxxxxxx, Account No xxxxxxxxxxx with direct SWIFT advice from the
remitting bank to XXXXXXN
Bank, xxxx Branch.

 

(c)                                  3rd
Installment

 

The BUYER
shall remit the amount of this installment in accordance with Article 2,
Paragraph 3(c) by telegraphic transfer to xxxxxxxx Bank, xxxx Branch, the
People’s Republic of China as receiving bank nominated by the SELLER, for
credit to the account of xxxxxsxxxxxxxxxxxxx Account No XXXNXXXXXX with direct SWIFT advice from the remitting bank to
xxxxxxx Bank, xxxx Branch.

 

(d)                                 4th
Installment

 

The BUYER
shall remit the amount of this installment in accordance with Article 2,
Paragraph 3(d) by telegraphic transfer to XXXXX.XXX Bank, ,xxx,
Branch, the People’s Republic of China as receiving bank nominated by the
SELLER, for credit to the account of XXXXN
XXXXXXX XXXXX Account No
xxxxxxxxxx with direct SWIFT advice from the remitting bank to xxxxx Bank, xxxx Branch.

 

(e)                                  5th
Installment (Payable upon delivery of the VESSEL)

 

The BUYER
shall, at least live (5) working days prior to the date of delivery, remit to
xxxxx Bank, xxxx Branch, the People’s Republic of China for credit to a
suspense account in the name of the BUYER or, at the option of the BUYER, in
the name of the bank which shall finance the payment by the BUYER of the fifth
installment with XXXXX
Bank, XXXX Branch, the
People’s Republic of China the amount of the fifth installment (as adjusted in
accordance with the provisions of this Contract), with an irrevocable
instruction that the said amount shall only be released to the SELLER against
presentation by the SELLER to the said xxxxx Bank, XXXXX Branch, the People’s
Republic of China, of one of the originals of the Protocol of Delivery and
Acceptance signed by the BUYER’s authorized representative and the SELLER.
Interest, if  any, accrued from such deposit,
shall he for the benefit of the BUYER.

 

If the
delivery or the VESSEL is not effected on or before the expiry of a period of
20 days commencing from the date on which the fifth installment is transferred
to the .xxxxx Bank, xxxxx Branch, the People’s Republic of China hi
accordance with this paragraph 4(e) of Article 2, the BUYER shall have the
right to withdraw the said deposit plus accrued interest upon the expiry of
such 20 days period. If, following the withdrawal by the BUYER of the fifth
installment of the Contract Price in accordance with this paragraph 4(e) of
Article 2, a new scheduled delivery date is notified to the BUYER by the SELLER
pursuant to, and in accordance with, this Contract, the BUYER shall remit the
fifth installment in accordance with the terms and conditions set out above.

 

(f)                                    Each
of the second, third and fourth installments of the Contract Price shall he due

and payable on the date falling five (5) banking days after receipt by the
BUYER

 

(i)                                    the
originals of the invoices referred to in paragraph (g) below which shall be accompanied
by stage certificates issued by the Classification Society., and

 

(ii)                                  An
original Letter of Relied Guarantee in respect of the relevant instalment of
the Contract price in the form attached to this Contract as Exhibit “B”.

 

The SELLER
shall be entitled, in respect of amounts due on fixed dates, to present
invoices in advance of the .due date for payment on the due date.

 

8

 

(g)                                 Upon
completion of each event entitling the SELLER to an instalment of the Contract
Price pursuant to paragraph 3 above, the SELLER shall send by telefax to the
BUYER on or after the relevant date, an invoice specifying the amount of the
instalment then due and shall send originals of such invoice in duplicate by
air courier to the BUYER, The BUYER shall be deemed to hay. received
such invoices five (5) banking
days after delivery to the acquirer.

 

5.                                       PREPAYMENT

 

The BUYER
shall have the right to make prepayment of any and all instalments before
delivery of the VESSEL, by giving to the SELLER at least thirty (30) days prior
written notice, without any price adjustment of the VESSEL for such prepayment. •

 

6.                                       SECURITY FOR PAYMENT OF INSTALMENTS
BEFORE DELIVERY

 

The BUYER
shall, upon effectiveness of this Contract, deliver to the SELLER a Performance
Guarantee in the form annexed hereto as Exhibit “A” in favour of the SELI ;ER
issued by AEGEAN BUNKERING SERVICES INC. (hereinafter called
the “Guarantor”). This guarantee shall secure all the Buyer’s obligations under
the Contract.

 

7.                                       REFUNDS

 

All payments
made by the BUYER prior to delivery of the VESSEL shall be in the nature of advance to the SELLER, and in the
event that in accordance with the specific terms of this Contract, the VESSEL
is rejected by the BUYER after the sea trial or this Contract is rescinded or
cancelled by the BUYER in accordance with the specific terms of this Contract
permitting such rescission or cancellation, the SELLER shall refund to the
BUYER in United States Dollars the full amount of all sums already paid by the
BUYER to the SELLER under this Contract, together with interest thereon (at the
applicable rate specified in this Contract) from the respective dates such sums
were received by the SELLER to the date of remittance by telegraphic transfer
of such refund to the BUYER.

 

As security to
the BUYER, the SELLER shall deliver to the BUYER, on or before receipt by the
SELLER of each instalment of the Contract Price, an original Refund Guarantee
securing the repayment of the relevant instalment of ‘the Contract Price to be
issued by China Construction Bank. Fujian branch, or China Communications Bank
the People’s Republic of China, or other Bank acceptable to the BUYER and BUYER’s
bank in respect of the relevant instalment of the Contract Price in the form
annexed hereto as Exhibit “B.”

 

ARTICLE 3 - ADJUSTIVIENT.OF THE CONTRACT PRICE

 

The Contract
Price of the VESSEL shall be subject to adjustments as hereinafter set forth.
It is hereby understood by both parties that any reduction of the Contract
Price is by way of liquidated damages and not by way of penalty.

 

1.                                       DELIVERY

 

(a)                                  No
adjustment shall be made and the Contract Price shall remain unchanged for the
first thirty (30) days of delay in delivery
of the VESSEL beyond the Delivery Date (as defined in Article 7 hereof and all references hereafter in this
Contract to the “Delivery Date”
shall be construed as references to that term as defined in Article 7 hereof) ending as of twelve o’clock
midnight of the thirtieth (30th)
day of delay.

 

(b)                                 If
the delivery of the VESSEL is delayed more than thirty (30) days after the Delivery Date, then, in such event:

 

9

 

	
  (i)

  	
  beginning at twelve o’clock midnight of the
  thirty-first (31st) to twelve o’clock midnight of the sixtieth
  (60th) day after the Delivery Date, the Contract Price of the VESSEL shall be
  reduced by deducting therefrom the sum of United States Dollars one thousand
  only (USD 1000.00) per day;

  
	
   

  	
   

  
	
  (ii)

  	
  beginning at
  twelve o’clock midnight of the sixty-first (61st to twelve o’clock
  midnight of the one hundred and one hundred-twenty (120th) day
  after the Delivery Date , the Contract Price of the VESSEL shall be reduced
  by deducting therefrom the sum of United States Dollars one thousand three
  hundred only (USD1300.00) per day.

  
	
   

  	
   

  
	
  (iii)

  	
  beginning at
  twelve o’clock midnight of the one hundred -twenty-first (121st)to
  twelve o’clock midnight of the one hundred and one hundred-eighty (I80th)
  day after the Delivery Date , the Contract Price of the VESSEL shall be
  reduced by deducting therefrom the sum of United States Dollars one thousand
  seven hundred fifty only (USDI,750b0) per day.

  

 

Unless the
parties hereto agree otherwise, the total reduction in the Contract Price shall
be deducted from the fifth installment of the Contract Price and in any event
(including the event
that the BUYER consents to take delivery of the VESSEL after the
expiration of the one hundred and eighty (180) day period of delay as described
in Paragraph 1(e) of this Article) the total reduction in the Contract Price
shall not he more than would be the case for a delay of one hundred and fifty
(150) days counting from midnight of the thirty-first (31st) day
after the Delivery Date at the above specified rates of reduction that is
United States Dollars Two Hundred and Thirteen Thousand only (USD 213,000.00).

 

(c)                                  the
delay in the delivery of the VESSEL exceeds a period of one hundred and eighty
(180) days after the Delivery Date, as defined in Article 7, then in such
event, and after such 180 days period has expired, the BUYER may, at any time
thereafter at its option, rescind or cancel this Contract in accordance with
the provisions of Article 10 of this Contract. The SELLER may at any time after
the expiration of the aforementioned one hundred and eighty (180) day period,
if the BUYER has not served notice of cancellation or rescission pursuant to
Article 10, demand in writing that the BUYER make an election (and in such
notice the SELLER shall specify a future delivery date for the VESSEL), in
which case the BUYER shall, within thirty (30) days after such demand is
received by the BUYER, either notify the SELLER of its decision to cancel this
Contract. or consent to take delivery of the VESSEL at an agreed future date,
it being understood and agreed by the parties hereto that, if the VESSEL is not
delivered by such future date, the BUYER shall have the same right of
rescission and cancellation upon the same terms, as hereinabove provided.

 

(d)                                 The
Contract Price shall not be adjusted or reduced if the delivery of the VESSEL

is delayed by reason of permissible delays as defined in Article 8 hereof

 

(e)                                  If
the SELLER notifies the BUYER by telefax That the delivery of the VESSEL, shall
be made earlier than the ‘Delivery Date and such notification is given not less
than one (1) month prior to the newly planned delivery date. a certain amount
of bonus shall be given by the BUYER to the SELLER.

 

Subject to the
above and in the event that the delivery shall be made within thirty (30) days
earlier than the Delivery Date, the Contract Price shall remain unchanged. In
the event that the delivery shall be made more than thirty (30) days earlier
than the specified Delivery Date, then a bonus shall be added to the Contract
Price at a rate of United States Dollars One Thousand Only (USD 1000.00) per
day for each full day earlier than the thirtieth (30th) day to sixtieth (60th)
day prior to the Delivery Date. And if the delivery will be made between sixty
(60) days and One Hundred and Twenty (120) days prior to

 

10

 

the Delivery
Date, a bonus shall be added to the Contract Price at a rate of United States
Dollars One Thousand Three hundred Only (USD1,300.00) per day for each full day.
And if the delivery will be made between One Hundred Twenty (120) days and One
Hundred Eighty (180) days earlier than the Delivery Date, a bonus shall be
added to the Contract price at a rate of United States Dollars One Thousand
Seven hundred fifty only (USD 1,750.00) per day for each full day.

 

The total increase of the
Contract Price for the earlier delivery shall be added to the fifth installment
of the Contract Price, but shall not he more in any case than an amount of
United States Dollars Two Hundred Thirteen Thousand only (USD213,000.00 ).

 

(f)                                    In
the event that the SELLER is  unable to deliver the Vessel on
the newly planned delivery date as declared, the VESSEL can, nevertheless, be
delivered by the SELLER at a date after such declared newly planned date.

 

In such circumstances, and
for the purpose of downsizing the liquidated damages to the BUYER (according to
the provisions of Paragraph 1 (b) of this Article) and the BUYER’s right to
cancel or rescind this Contract (according to the provisions of Paragraph I (c)
of this Article), the newly planned delivery date declared by the SELLER shall
not be in any way he treated or be taken as having
substituted the original Delivery Date as defined in Article 7. The BUYER’s aforesaid right for
liquidated damages and to cancel or rescind this Contract shall be accrued,
operated or exercised only to the extent as described in Paragraph 1 (a), 1 (b)
and/or 1 (c) of Article 3. In whatever circumstances, the Delivery Date as
defined in Article 7 (not .the newly planned delivery date as
declared by the SELLER) shall be used to regulate, as so
described in Paragraph 1 (a), 1 (b) and/or 1 (c) of Article 3, the BUYER’s
right for liquidated damages and to rescind this Contract and the SELLER’S
liability to pay the aforesaid liquidated damages resulting from the delay in
delivery of the -VESSEL

 

2.                                       INSUFFICIENT
SPEED

 

(a)                                  The
Contract Price of the VESSEL
shall not be affected nor changed by reason of the actual speed (as described
in detail in the Specifications
and as determined by the Trial Run according to the Specifications) being equal
to or less than three-tenths (3/10) of one knot below the guaranteed speed as
specified in Paragraph 4 of Article I of this Contract.

 

(b)                                 However,
commencing with and including a deficiency of more than three-tenths (3/10) of
one knot in actual speed (as determined by the Trial Run according to the
Specifications) below the guaranteed speed as specified in Paragraph 4 of
Article 1 of this Contract, the Contract Price shall be reduced as follows:

 

In case of deficiency

Above 0.30 but below or
at 0.40 knot               USD   5,000 (Total)

Above 0.40 but below or at
0.50 knot               USD 10,000 (Total)

Above 0.50 but below or at 0.60 knot               USD
15,000 (Total)

Above 0.60 but
below or at 0.70 knot               USD 20,000 (Total)

Above 0.70 but
below or at 0.80 knot               USD 25,000 (Total)

Above 0.80 but
below or at 0.90 knot               USD 40,000 (Total)

 

(c)                                  If
the deficiency in actual speed (as determined by the Trial Run after correction
according to the Specifications) of the VESSEL upon the Trial Run, is more than
nine tenths (9/10) of one knot below the guaranteed speed of 12.5 knots, then
the BUYER may at its option reject the VESSEL and rescind this Contract in accordance
with provisions of Article 10 of this Contract, or may accept the VESSEL at a
reduction in  the Contract Price as above
provided for nine tenths (9/10) of one knot, that is United States Dollars
forty thousand only (USD 40,000) being the maximum.

 

11

 

3.                                       DEADWEIGHT

 

(a)                                  In
the event that there is a deficiency in the actual deadweight of the VESSEL
determined as provided in the Specifications, the Contract Price shall he
decreased by the sum of United States Dollars One Thousand only (USD 1000) for
each metric ton in case of deficiency of the guaranteed deadweight of 3800
metric tons at assigned design summer draught 5.50m and up to a maximum
deficiency of three hundred (300) metric tons..

 

(b)                                 In
the event that there should be a deficiency in the VESSEL’s actual deadweight
Which exceeds three hundred (300) metric tons below the guaranteed deadweight,
the BUYER may, at its option, reject the VESSEL and rescind this Contract in
accordance with the provisions of Article 10 of this Contract, or may accept
the VESSEL with reduction in the Contract Price in the maximum amount of United
States Dollars Three Hundred thousand only (USD 300,000.00).

 

(c)                                  In
the event that the actual deadweight of the VESSEL exceeds 3800 metric tons,
then a bonus shall be added to the Contract Price at a rate of United States
Dollars five hundred (500) per each metric ton in excess of 3800 metric tons
but in any ease up to a maximum amount of United States Dollars Seventy Five
Thousand (USD 75,000.00)

 

The total
reduction or increase, as the case may be, in the Contract Price as the result
of the operation of the provisions of this paragraph 4 of Article 3 shall be
applied in reducing or increasing the fifth installment of the Contract Price.

 

4.                                       EFFECT
OF RESCISSION

 

It is
expressly understood and agreed by the parties hereto that in any case as
stated herein, if the BUYER rescinds this Contract pursuant to any provision
under this Article, the BUYER, save its rights and remedy set out in Article 10
hereof, shall not be entitled to any liquidated damage but shall be entitled to
a refund of payments made prior to delivery and interest thereon.

 

ARTICLE 4 - APPROVAL OF PLANS AND DRAWINGS - SUPERVISION
AND INSPECTION

 

1.                                       APPOINTMENT
O THE BUYER’S SUPERVISOR

 

The BUYER
shall send in good time to and maintain at the SELLER’s Shipyard, at the BUYER’s
own cost and expense, one or more representative(s) who shall be duly
accredited in writing by the BUYER (such representative(s) being hereinafter
collectively and individually called the “Supervisor”) to attend, inspect
supervise and survey the construction of the VESSEL, her engines and
accessories.

 

The SELLER
Shall make all necessary arrangements to assist BUYER’s Supervisor to obtain
all necessary visas, permits, license, work permits etc. so as to enable
him/them to attend the Construction of the VESSEL in good time.

 

The SELLER
hereby undertakes to assist in order to get the necessary visa for the
Supervisor to enter China will be issued upon demand and without delay provided that the Supervisor meets with the rules,
regulations and laws of the People’s Republic of China. The BUYER undertakes to
give the SELLER adequate notice for the application of visa.

 

2.                                       APPROVAL
OF PLANS AND DRAWINGS

 

The parties
hereto shall, within thirty (30) days after signing of this Contract, mutually
agree a Hat of all the plans and drawings, which are to be sent to the BUYER
for approval (hereinbelow called “the LIST”). Before arrival of the Supervisor
at the SELLER’S Shipyard, the plans and drawings

 

12

 

specified in
the LIST shall be sent to the BUYER, and the BUYER shall, within ten (10) days
after receipt thereof (excluding mailing time), return such plans and drawings
submitted by the SELLER. with approval or remarks, if any. Such approvals and
remarks shall he in accordance with the Contract and Specifications.

 

Concurrently
with the arrival of the Supervisor at the SELLER’s Shipyard, the BUYER shall
notify the SELLER in writing, stating the authority which the said Supervisor
shall have and stating whether the Supervisor can, on behalf of the BUYER,
approve or disapprove, as the case may be, those plans and drawings specified
in the LIST which have not yet been sent to the BUYER. Should the Supervisor be
so authorised by the BUYER, the Supervisor shall, within five (5) days after
receipt thereof, return those plans ands drawings its approval or remarks, if
any.

 

Unless
notification is given to the SELLER by the Supervisor or the BUYER of approval
or disapproval of any plans and drawings within the above-designated period of
time for each case, the said plans and drawings shall be deemed to have been
automatically approved,

 

The plans and
drawings approved by the BUYER or the Supervisor shall be final, and any
alteration thereof shalt be regarded as modification specified in Article 5 of
this Contract.

 

3.                                       SUPERVISION
AND INSPECTION BY THE SUPERVISOR

 

The Supervisor
shall have, at all times until delivery of the VESSEL, the right to attend
tests according to the mutually agreed test list and inspect the VESSEL, her
engines, accessories and materials at the SELLER’s Shipyard, the premises of
its subcontractors or any other place where work is done or materials stored in
connection with the VESSEL, In the event that the Supervisor discovers any
construction or material or workmanship which does not or will not conform to
the requirements of this Contract and the Specifications, the Supervisor shall
promptly give the SELLER a notice in writing as to such nonconformity, upon
receipt of which the SELLER shall correct such nonconformity if the SELLER
agrees with the BUYER. However the BUYER undertakes and assures the SELLER that
the Supervisor shall carry out his inspections in accordance with the agreed
inspection procedure and schedule and usual shipbuilding practice and in a way
as to minimize any increase in building costs and delays in the construction or the VESSEL.

 

The SELLER
agrees to furnish free of charge the Supervisor with office space, and other
reasonable facilities according to SELLER’s practice at, or in the immediate
vicinity of the SELLER’s Shipyard as may he necessary to enable the Supervisor
to effectively carry out his duties. All international communication charges
(such as telephone and telefax charges) shall be borne by the BUYER. At all
times, during the construction of the VESSEL until delivery thereof, the
Supervisor shall be given free and ready access to the VESSEL, her engines and
accessories, and to any other place where the work is being done, or the
materials are being processed or stored, in connection with the construction of
the VESSEL, including the yards, workshops, stores of the SELLER, and the
premises of subcontractors of the SELLER, who are doing work, or storing
materials in connection with the VESSEL’S construction. The travel expenses for
the said access to SELLER’s subcontractors-outside of Fuzhou city
shall be at BUYER’s account. The transportation within Fuzhou city shall be
provided to the Supervisor by the SELLER.

 

4.                                       LIABILITY
OF THE SELLER

 

The Supervisor
engaged by the BUYER under this Contract shall at all times be deemed to be in
the employment of the BUYER, The SELLER shall be no liability whatsoever to the
BUYER, or to the Supervisor or the BUYER’s employees or agents for personal injuries,
including death, during the time when they, or any of them, are on the VESSEL,
or within the premises of either the SELLER or its subcontractors, or are
otherwise engaged in and about the construction of the VESSEL, unless, however,
such personal injuries, including death, were caused by the

 

13

 

negligence or
willful misconduct of the SELLER, or of any of the SELLER’s -employees or
agents or subcontractors of the SELLER. Nor shall the SELLER have any liability
whatsoever to the BUYER for damage to, or loss or destruction of property in
China of the BUYER or of the Supervisor, or of the BUYER’s employees or agents,
unless such damage, loss or destruction is caused by the negligence or willful
misconduct of the SELLER, or of any of the employees, or agents or
subcontractors of the SELLER.

 

5.                                       SALARIES
AND EXPENSES

 

All salaries
and expenses of the Supervisor, or any other employees employed by the BUYER
under this Article, shall he for the BUYER’s account.

 

6.                                       REPLACEMENT
OF SUPERVISOR

 

The SELLER has
the right to request the BUYER in writing to replace any of the Supervisors who
is proved to be unsuitable and unsatisfactory for the proper progress of the
VESSEL’s construction together with reasons, The BUYER shall investigate the
situation by sending its representative to the SELLER’s yard, if necessary, and
if the BUYER considers that such SELLER’S request is justified, the BUYER shall effect the replacement
as soon as conveniently arrangeable.

 

7.                                       The
supervisors or employees will be informed by the BUYER to follow the Laws of
P.R. of China when they work in China.

 

ARTICLE 5 - MODIFICATION, CHANGES AND EXTRAS

 

1.                                       HOW
EFFECTED

 

The
Specifications and Plans in accordance with which the VESSEL shall be
constructed, may be modified and/or changed at any time hereafter by written
agreement of the parties hereto, provided that such modifications and/or
changes or an accumulation thereof will not, :in the SELLER’s reasonable
judgement, adversely affect the SELLER’s other commitments and provided further
that the BUYER shall consent, if necessary, to affair and reasonable adjustment
of the Contract Price, time of delivery of the VESSEL., and other terms of this
Contract, and/or the Specifications occasioned by such modification and/or
changes, it any. as hereinafter provided. Subject to the above, the SELLER
hereby agrees to exert ifs’ best efforts to accommodate such reasonable
requests by the BUYER so that the said changes and/or modifications may be made
at a reasonable cost and within the shortest practicable time. Any such
agreement for modifications and/or changes shall include an agreement as to the
increase. or decrease, if any, in the Contract Price of the VESSEL together
with an agreement as to any extension or reduction hi the date of delivery, the
provision to the SELLER of any additional securities necessary to the SELLER,
or any other alterations in this Contract, or the Specifications occasioned by
such - modifications and/or changes. The aforementioned agreement to modify
anchor to change the Specifications may be effected by an exchange of letter,
or telefaxes signed in each case by an authorised representative of the
relevant party, manifesting such agreement. The letters as well as telefaxes
exchanged by the parties hereto pursuant to the foregoing shall constitute an
amendment to the Specifications under which the VESSEL shall be built, and such
letters and telefaxes shall be deemed to be incorporated into this Contract and
the Specifications by reference and made a part hereof. Upon consummation of
the agreement to modify and/or to change the Specifications, the SELLER shall
without delay alter the construction of the VESSEL in accordance therewith,
including any additions to, or deductions from, the work to he performed in
connection with such construction. If due to whatever reasons, the parties
hereto shall fail to agree on the adjustment of the Contract Price or extension
of time of delivery or the provision of additional security to the SELLER or
modification of any terms of this Contract which are necessitated by such
modifications and/or changes, then

 

14

 

the SELLER
shall have no obligation to comply with the BUYER’s request for any
modification and/or changes.

 

2.                                       CHANGES
IN RULES OF CLASSIFICATION SOCIETY REGULATIONS ETC.

 

(1)                                  If,
after the date of signing this Contract, any requirements as to classification
or as to the rules and regulations as specified in this Contract and the
Specifications to which the construction of the VESSEL is required to conform,
are altered or changed by the Classification Society or any regulatory bodies
authorized to make such alterations or changes, the SELLER and/or the BUYER,
upon receipt of information thereof, shalt transmit such information in full to
each other in writing, whereupon within twenty-one (21) days after receipt of
the said notice by the BUYER from the SELLER or vice versa, the BUYER shall instruct
the SELLER in writing as to the alterations or changes, if any, to be made in
the VESSEL which the BUYER, in its sole discretion, shall decide. The SELLER
shall promptly comply with such alterations or changes, if any in the
construction of the VESSEL provided that the BUYER shall first agree:

 

(a)                                  As
to any fair increase or decrease in the Contract Price of the VESSEL that is
fairly and reasonably occasioned by the cost for such compliance; and/or

 

(b)                                 As
to any extension in the time of delivery of the VESSEL that is necessary due to
such compliance; and/or

 

(c)                                  As
to any increase or decrease in the guaranteed deadweight and/or speed of the
VESSEL, if such compliance results in increased or reduced deadweight and/or
speed; and/or

 

(d)                                 As
to any other alterations in the terms of this Contract or of the Specifications
or both, if such compliance makes such alterations of the terms necessary; .and/or

 

(e)                                  If
the Contract Price is to be increased, then, in addition or as an alternative
to any of the provisions above, as to the provision of additional security by
the BUYER to the SELLER if deemed necessary by the SELLER.

 

Agreement as
to such alterations or changes under this Paragraph shall he made in the same
manner as provided in Paragraph I of this Article for modifications and/or
changes of the Specifications and/or Plans.

 

(2)                                  If
due to whatever reasons, the parties shall fail to agree on the adjustment of
the Contract Price or extension of the time for delivery or increase or
decrease of the guaranteed speed and deadweight or the provision of additional
security to the SELLER or any alteration of the terms of this Contract, if any,
then the SELLER shall be entitled to proceed with the construction of the
VESSEL in accordance with, and the BUYER shall continue to be bound by, the
terms of this Contract and the Specifications without making any such
alterations or changes provided the survey of the Class and the issuance of the
Certificates by the Class and relevant authorities will not be affected.

 

3.                                       SUBSTITUTION
OF MATERIALS AND/DR EQUIPMENT

 

In the event
that any of the materials and/or equipment required by the Specifications or
otherwise under this Contract for the construction of the VESSEL cannot be
procured in time to maintain the Delivery Date of the VESSEL, the SELLER may,
provided that the BUYER shall so agree first in writing, supply other materials
and/or equipment of the same standard and quality in accordance with the
requirements of the Classification Society and of the rules, regulations and

 

15

 

with which the
construction of the VESSEL must comply in accordance with the terms of this
Contract and the Specifications.

 

4.                                       BUYER’S
SUPPLIED ITEMS

 

The BUYER
shall deliver to the SELLER at its shipyard the items as specified in the
Specifications which the BUYER shall supply on its account by the time mutually
agreed by the SELLER and the BUYER.

 

Should the
BUYER fail to deliver to the SELLER such items within the time, agreed, the
delivery of the VESSEL shall automatically be extended for a period of such
delay, provided always that such delay in delivery of the BUYER’s supplied
items shall actually have affected the delivery of the VESSEL. In such event,
the BUYER shall pay to the SELLER all losses and damages sustained by the SELLER due to such delay in the
delivery of the BUYER’S supplied items and such payment shall be made upon
delivery of the VESSEL, but only provided that the construction program is
actually affected.

 

Furthermore,
if the delay in delivery of the BUYER’s supplied items should exceed twenty
(20) days, the SELLER shall be entitled to proceed with the construction of the
VESSEL without installation of such items in or onto the VESSEL, without
prejudice to the SELLER’S right hereinabove provided, and the BUYER shall
accept the VESSEL, so completed.

 

The SELLER
shall be responsible for safely storing and handling of the BUYER’s supplies as
specified in the Specifications after delivery to the SELLER and shall install
and secure them on board the VESSEL at the SELLER’S expenses. The extra cost
for material installation or testing for Buyer’s supplied items, if any, will
be borne by the Buyer.

 

Upon arrival
of such shipment of the Buyer’s supplied items, both parties shall undertake a
joint unpacking inspection. if any damages are found to be not suitable for
installation, the SELLER shall be entitled to refuse to accept the BUYER’s
supplied items.

 

ARTICLE 6 - TRIALS

 

1.                                       NOTICE

 

The Sea Trials
will start when the VESSEL is completed according to the relevant provisions of
the Specifications.

 

The BUYER and
the Supervisor shall receive from the SELLER at least-thirty (30) days notice
in advance and five (5) days definite notice in advance in writing or by
telefax, of the time and place of the VESSEL’s sea trial as described in the
Specifications (hereinafter referred to as “the Trial Run”) and the BUYER and
the Supervisor shall promptly acknowledge receipt of such notice. The BUYER’s
representatives and/or the Supervisor shall be on board the VESSEL to witness
such Trial Run, and to check upon the performance of the VESSEL during the same.
The BUYER’s officers and crew may also attend onboard the VESSEL to witness the
Sea Trials. Failure of the BUYER’s representatives to be present at the Trial
Run of the VESSEL, after due notice to the BUYER and the Supervisor as provided
above, shall have the effect to extend the date for delivery of the VESSEL by
the period of delay caused by such failure to be present. However, if the Trial
Run is delayed more than seven (7) days by reason of the failure of the BUYER’s
representatives to be present after receipt. of due notice as provided above,
then in such event, the BUYER shall be deemed to have waived its right to have
its representatives on board the VESSEL during the Trial Run, and the SELLER
may conduct such Trial Run without the BUYER’s representatives being present
but with the Classification Society Surveyor(s) always in attendance, and in
such case the BUYER shall be obliged to accept. the VESSEL on the basis of a
certificate jointly signed by the SELLER and the Classification Society
certifying that the

 

16

 

VESSEL, after
Trial Run, subject to completion of minor alterations and corrections as provided
in this Article, if any, is found to conform to the Contract and Specifications
and is satisfactory in all respects.

 

The SELLER
hereby undertakes to assist the buyer to get the necessary visas and permits
for the BUYER’s representatives to enter China will be issued in order to
enable them attend the Trial Run, on demand and without delay.

 

In the event
of unfavourable weather on the date specified for the Trial Run, the same shall
take place on the first available day thereafter that the weather conditions
permit. The parties hereto recognize that the weather conditions in Chinese
waters in which the Trial Run is to take place are such that great changes in
weather may arise momentarily and without warning and, therefore, it is agreed
that if during the Trial Run of the VESSEL the weather should suddenly become
unfavourable, as would have precluded the continuance of the Trial Run, the
Trial Run of the VESSEL shall be discontinued and postponed until the first
favourable day next following, unless the BUYER shall assent in writing, or by
telefax of its acceptance of the VESSEL on the basis of the Trial Run made
prior to such sudden change in weather conditions.

 

In the event
that the Trial Run is postponed because of unfavourable weather conditions,
such delay shall be regarded as a permissible delay, as specified in Article 8
hereof.

 

2.                                       HOW
CONDUCTED

 

(a)                                  All
expenses in connection with Trial Run of the VESSEL or any re-Trial or
re-Trials are to be for the account of the SELLER, who, during the Trial Run
and when subjecting the VESSEL to Trial Run, is to provide, at its own expense,
the necessary crew to comply with conditions of safe navigation. The Trial Run
shall be conducted in the manner prescribed in the Specifications and shall
prove fulfilment of the performance required for the Trial Run as set forth in
the Specifications.

 

The course of
Trial Run shall be determined by the SELLER and shall be conducted within the
trial water equipped with speed measuring facilities.

 

(b)                                 The
SELLER shall provide the VESSEL with the required quantities of water and fuel oil , lubrication oil, hydraulic oil,
greases and other stores necessary for the conduct of the Trial Run or Trial
Runs which shall be supplied by the SELLER, as prescribed in the Specifications. The
fuel oil, lubricating oil, hydraulic oil and greases shall be in accordance
with the applicable engine specifications. And the cost of the quantities of
water, fuel oil, lubricating oil, hydraulic oil and greases consumed during the
Trial Run or Trial Runs shall be for the account of the SELLER.

 

3.                                       TRIAL
LOAD DRAFT

 

In addition to
the supplies provided by the SELLER in accordance with sub-paragraph (b) of the
preceding Paragraph 2 hereof, the SELLER shall provide the VESSEL with the
required quantity of fresh water and other stores necessary for the conduct of
the Trial Run. The necessary ballast (fresh water, sea water or any other
ballast as may be required) to bring the VESSEL to the trial load draft as
specified in the Specifications shall be for the SELLER’S account.

 

4.                                       METHOD
OF ACCEPTANCE OR REJECTION OF TRIAL RUN RESULT

 

(a)                                  Upon
notification of the SELLER of the completion of the Trial Run of the VESSEL,
the BUYER or the BUYER’s Supervisor shall within ten (10) days thereafter,
notify the SELLER in writing or by telefax of its acceptance of the VESSEL
TRIAL RUN RESULT or of its rejection of the VESSEL TRIAL RUN RESULT together
with the reasons therefor.

 

17

 

(b)                                 However,
should the result of the Trial Run indicate that the VESSEL or any part thereof
including its equipment does not conform to the requirements of this Contract
and/or the Specifications, then the SELLER and the BUYER shall investigate with
the BUYER’s Supervisor the cause of failure and the proper steps shall be taken
to remedy the same and shall make whatever corrections and alterations and/or
re-Trial Run or Runs as may be necessary without extra cost to the BUYER, and
upon notification by the SELLER of completion of such alterations or
corrections and/or re-trial or re-trials, the BUYER shall, within ten (10) days
thereafter, notify the SELLER in writing or by telefax of its acceptance or
rejection of the TRIAL RUN RESULT together with the reason therefor on the
basis of the alterations and corrections and/or re-trial or re-trials by the
SELLER.

 

(c)                                  In
the event that the BUYER fails to notify the SELLER in writing or by telefax of
its acceptance or rejection of the VESSEL TRIAL RUN RESULT together with the
reason therefor within the ten (10) thy period provided for in sub-paragraphs
(a) and (b) above, the BUYER shall be deemed to have accepted the VESSEL TRIAL
RUN RESULT.

 

(d)                                 Any
dispute arising among the parties hereto as to the result of any Trial Run or
further tests or trials, as the case may be, of the VESSEL shall he solved by
reference to Arbitration as provided in Article 13, of this Contract.

 

(e)                                  Nothing
herein shall preclude the BUYER from accepting the VESSEL with its
qualifications and/or remarks following the Trial Run and/or further tests or
trials as aforesaid and the SELLER shall be obliged to comply with and/or
remove such qualifications and/or remarks at the time before- effecting
delivery of the VESSEL to the BUYER under this Contract. However, in case there
is any minor qualification and/or remark which does not affect the VESSEL’s
performance and/or VESSEL’S class rules and regulations and/or VESSEL’s Class
or statutory Certificates the delivery of the VESSEL to the BUYER shall not be
affected, provided that the SELLER shall expressly undertake in writing to
comply with and/or remove such minor qualifications and/or remarks the soonest
practically possible within the Guarantee period of the VESSEL which extends to
one (1) year from the date f delivery of the VESSEL, to the BUYER.

 

5.                                       DISPOSITION
OF SURPLUS CONSUMARI,E STORES

 

Should any
amount of .fuel oil, fresh water, or other untouched consumable
stores furnished by the SELLER for the Thai Run or Trial Runs remain on board
the VESSEL at the time of acceptance thereof by the BUYER, the BUYER agrees to
buy the same from the SELLER at the purchasing price at the port or delivery thereof, and payment by
the BUYER shall be effected as provided in  paragraphs
3 (c) and 4 (e) of Article 2 of this Contract.

 

6.                                       EFFECT
OF ACCEPTANCE

 

The BUYER’s
acceptance of the VESSEL in writing or by telefax notification sent to the
SELLER, in accordance with the provisions set out above, shall be final and
binding so far as conformity of the VESSEL to this Contract and the Specifications
is concerned, and shall preclude the BUYER from refusing formal delivery by the
SELLER of the VESSEL, as hereinafter provided, if the SELLER complies with all
other procedures and requirements for delivery as hereinafter set forth.

 

ARTICLE 7 - DELIVERY

 

1.                                       TIME
AND PI ACE

 

The VESSEL
shall be delivered safely afloat by the SELLER to the BUYER at the .SELLER’s
Shipyard, in accordance with the Specifications, and with all Classification
and Statutory Certificates which are required to be provided by the SELLER in
accordance with the relevant

 

18

 

provisions of
the Specifications and all other applicable terms and conditions of this
Contract and after completion of Trial Run (or, as the case may be, re-Trial or
re-Trials) and acceptance by the BUYER in accordance with the provisions of
Article 6 hereof on or before August 31.2009, provided that in the event of
delays in the construction of the VESSEL due to causes which, under the terms
of the Contract, permit the postponement of the date of delivery, the
aforementioned time for delivery of the VESSEL shall be extended accordingly.

 

The
aforementioned date or such later date to which delivery is extended or agreed
to be extended pursuant to the terms of this Contract is hereinafter called the
“Delivery Date”.

 

2.                                       WHEN
AND HOW EFFECTED

 

After the
VESSEL is accepted following the sea trials and once the VESSEL is ready for
delivery, the SELLER shall  give
the BUYER three (3) business days definite notice of the anticipated delivery
date by letter, telefax or telex to the BUYER.

 

Provided that
the BUYER and the SELLER shall each have fulfilled all of their respective
obligations as stipulated in this Contract, and the VESSEL is ready for
delivery, the delivery of the VESSEL shall be effected forthwith by the
concurrent delivery by each of the parties hereto, one to the other, of the
Protocol of Delivery and Acceptance, duly signed by the parties, acknowledging
delivery of the VESSEL by the SELLER and acceptance thereof by the BUYER.

 

3.                                       DOCUMENTS
TO BE DELIVERED TO THE BUYER

 

Concurrently
with the delivery and acceptance of the VESSEL by the BUYER. the SELLER shall
deliver to the BUYER the following duly authenticated documents, which shall
accompany the Protocol of Delivery and Acceptance (which shall he prepared in
three originals and executed by each of the parties hereto):

 

(a)                                  PROTOCOL
OF TRIALS of the VESSEL made by the SELLER pursuant to the Specifications,

 

(b)                                 PROTOCOL
OF INVENTORY of the equipment of the VESSEL including spare parts and the like,
all as specified in the Specifications, made by the SELLER,

 

(c)                                  PROTOCOL
OF STORES OF CONSUMABLE NATURE
made by the SELLER referred to under Paragraph 5 of Article 6 hereof.

 

(d)                                 FINISHED
DRAWINGS AND PLANS pertaining to the VESSEL as stipulated in the
Specifications, made by the SELLER.

 

(e)                                  PROTOCOL
OF LIGHTSHIP AND INCLINING EXPERIMENT, as per the Specification made by the
SELLER.

 

(f)                                    ALL
CLASSIFICATION AND OTHER CERTIFICATES required to be furnished upon delivery of
the VESSEL pursuant to this Contract and the Specifications.

 

It is agreed that if through no fault on the
part of the SELLER the full terms Classification certificate and/or any other
certificates referred to in this subparagraph (f) cannot be issued at. the time
of delivery of the VESSEL, then provisional certificates as issued by the
Classification Society or any third party shall be accepted by the BUYER,
provided that the SELLER shall furnish the BUYER with the full tom formal
certificates as promptly as possible (but in any event before the expiry of the
provisional certificates).

 

19

 

(g)                                 the
BUILDER’S CERTIFICATE issued by the SELLER in three (3) originals, each duly
notarised by the local authority.

 

(h)                                 DECLARATION
OF WARRANTY issued by the SELLER that the VESSEL is delivered to the BUYER free
and clear of any liens, charges, claims, mortgages, or other encumbrances
whatsoever upon the BUYER’s title thereto, and in particular, that the VESSEL
is absolutely free of all burdens in the nature of imposts, taxes levies, dues
or charges imposed by the relevant authorities of the province or country of
the port of delivery, as well as of all liabilities of the SELLER to its
sub-contractors, employees and crews and/or of all liabilities arising from the
operation of the VESSEL in Trial Run or Trial Runs, or otherwise, prior to
delivery and any other liabilities, debits or obligations whatsoever ensuing
from and cause or reason whatsoever.

 

(i)                                     COMMERCIAL
INVOICE made by the SELLER.

 

(j)                                     BILL
OF SALE made by the SELLER in 3 originals. each duly notarised by the local
authority.

 

4.                                       TITLE AND RISK

 

Title to and
risk of the VESSEL shall pass to the BUYER only upon the delivery and
acceptance thereof having been completed as stated above; it being expressly
understood that, until such delivery is effected, title to the VESSEL, and her
equipment, shall remain with the SELLER and be at the entire risk of the
SELLER.

 

5.                                       REMOVAL
OF VESSEL

 

The BUYER
shall take possession of the VESSEL immediately upon delivery and acceptance
thereof by the BUYER and shall remove the VESSEL from the premises of the
SELLER within seven (7) days after delivery and acceptance thereof is effected,
Following delivery of the VESSEL, the SELLER shall not charge the BUYER for the
costs of mooring the VESSEL at the SELLER’s premises within these seven (7)
days. If the BUYER shall not remove the VESSEL from the premises of the SELLER
within the aforesaid seven (7) days, in such event, after the lapse of this
seven (7) days period for reasons other than Chinese Authorities’ restrictions
or reasons entirely beyond the control of the BVYIER the BUYER shall pay to the
SELLER United States Dollars Two Thousand only (USD2000) per day as reasonable
mooring charge of the VESSEL.

 

In case of
early delivery the BUYER shall have the option to keep the VESSEL at least two
(2) weeks at the SELLER’S premises. If the BUYER shall not remove the VESSEL
from the premises of the SELLER within the aforesaid two (2) weeks, in such
event, the BUYER shall pay to the SELLER thereafter United States Dollars Two
Thousand only (USD2000) per day as reasonable mooring charge of the VESSEL.

 

6.                                       TENDER
OF THE VESSEL

 

If the BUYER fails to
take delivery of the VESSEL within one (1) month after completion thereof
according to this Contract and the Specifications without justified reason, the
SELLER shall have the right to tender the VESSEL for delivery after compliance
with all procedural requirement as above provided.

 

20

 

ARTICLE 8 - DELAYS & EXTENSION OF E FOR DELIVERY

 

1.                                       CAUSE
OF DELAY

 

If, at any
time before the agreed delivery date, either the construction of the VESSEL, or
any performance required hereunder as a prerequisite of delivery of the VESSEL
is actually prevented or delayed due to any of the following
supervening events beyond the SELLER’s reasonable foresight and control,
namely, war, blockade, revolution, political upheavals insurrection,
mobilization, civil continuums, riots, strikes, sabotage, lockouts, Acts of God
or the public enemy, plague or other epidemics, guaranties, prolonged failure
of electric current from an outside source, freight embargoes, if any,
extremely hot temperature (above 39 degrees C in accordance with official data
of the national meteorological institute). earthquakes, tidal waves typhoons,
hurricanes, storms or other similar causes beyond the reasonable control of the
SELLER, or of its subcontractors, as the case may be, which were not existing
and known to the SELLER and could not reasonably have been foreseen or
prevented by the SELLER at the date of signing of this Contract, or by
destruction of the premises of the SELLER or its subcontractors, or of the
VESSEL or any part thereof, by fire or flood which could not have been
prevented by the SELLER, or due to the Bankruptcy of the equipment suppliers
and/or material suppliers., the SELLER having exercised due diligence in
selecting the Suppliers and having done their utmost to arrange a substitute,
or due to the delay caused by Acts of God in  supply
of parts essential to the construction of the VESSEL, then, in the event of
delay actually due to the happening of any of the aforementioned contingencies,
the SELLER shall not be liable for such delay and the time for delivery of the
VESSEL under this Contract shall be extended without any reduction in the
Contract Price for a period of time which shall not exceed the total
accumulated time of all such delays during which the construction of the VESSEL
was actually delayed beyond the reasonable control of the SELLER as a direct
result of such event. All the above are subject nevertheless to the BUYER’s
right of cancellation under Paragraph 3 of  this
Article and subject to all relevant provisions of this Contract which authorize
and permit extension of the time of delivery of the VESSEL.

 

It is
specifically agreed that for a delay, which is caused by the late delivery to
the SELLER of machinery, equipment and supplies to be incorporated in the
VESSEL, to be considered as caused by an event described in the previous
paragraph, it should be determined that the SELLER when contracting for such
machinery, equipment and supplies was expeditious and prudent, that he has
exercised due diligence in the performance of any acts required of its part,
and that he has exercised due diligence in expediting deliveries under the
SELLER’s Purchase Contract or in seeking equivalent convenient substitute
performance., and in case of late performance or default of a sub-contractor or
supplier, it should he also determined that the SELLER’s choice of the
sub-contractor was reasonable and responsible and that the SELLER has exerted
all reasonable efforts to expedite performance, avoid default or procure
reasonable substitute performance.

 

It is also
specifically agreed that if any of the above events is to occur, the SELLER
shall use due diligence and shall as soon as possible take all necessary and
reasonable steps in order to avoid and/or reduce and/or prevent and/or mitigate
any possible ensuing delay.

 

The SELLER shall not be entitled to any
extension of the Contract Delivery Date and any of the types of delay listed
below which may occur, shall he regarded as non-permissible delays:

 

(i)                                     Any
delay resulting from the SELLER’s own breach of contract, or fault, or
negligence or that of any of its employees or breach of Contract or fault of its agents, subcontractors or other
suppliers.

 

(ii)                                  Any
delay resulting from a cause of delay already in existence at the time

of signing of this Contract.

 

21

 

2.                                       NOTICE
OF DELAY,

 

Within seven
(7) days from the date of commencement of any of the above-mentioned causes of
delay on account of which the SELLER claims that it is entitled under this
Contract to an extension of the time for delivery of the VESSEL, the SELLER
shall advise the BUYER by letter, telefax or telex, of the date on which such
delay commenced and
describing in all its details the nature of the event which caused the
delays.

 

In the event
of the delay continuing for more than fourteen (14) days, further notice, by
letter, telex or telefax shall be given to the BUYER every seven (7) days thereafter setting out the
same particulars, as aforesaid, until the causes of the delay have ended.

 

Likewise
within seven (7) days after such cause of delay ends, the SELLER shall advise
the BUYER by letter, telefax or telex, of the date such cause of delay ended,
and also shall specify the maximum period- of the time by which in
the SELL ER’s Opinion the date for delivery of the VESSEL should be extended by
reason of such cause of delay. Failure of the BUYER to object to the SELLS R’s
notification of any claim for extension of the Delivery Date within thirty (30)
days after receipt by the BUYER of such notification, shall be deemed to be a
waiver by the BUYER of its right to object to such extension.

 

The SELLER
shall also immediately take steps to mitigate the effects of the delay and to
accurately determine the period by which the Delivery Date is going to be
postponed by reason of the aforementioned events and shall immediately notify
the BUYER in writing accordingly.

 

If the SELLER
does not give the aforementioned advice forthwith the SELLER shall lose the
right to claim such delay as permissible delay and any right of postponement of
delivery date.

 

3.                                       RIGHT
TO CANCEL FOR EXCESSIVE DELAY.

 

If the total
accumulated time of all delays on account of the causes specified in Paragraph
I of this Article aggregate to One Hundred and Eighty (180) days or more,
excluding delays awarded by an arbitration as specifically provided fir in
Article 13 hereof, and excluding delays which are caused due to default in
performance by the BUYER, or due to delays in delivery of the Buyer’s supplied
items or due to causes which, under Article 4,5,6,11 and 12 hereof, permit
extension or postponement of the time for delivery of the VESSEL, then in such
event, the BUYER may in accordance with the provisions set out. herein rescind/
cancel this Contract.

 

The SELLER
may, at any time, after the accumulated time of the aforementioned delays
justifying cancellation by the BUYER as above, demand
in writing that the BUYER shall make an election, in which ease the BUYER
shall, within fifteen (I5) days after such demand is received by the BUYER
either notify the SELLER of its intention to cancel, or consent to an extension
of the Delivery Date to an agreed future date. If any further delay occurs on
account of causes justifying cancellation as specified in this Contract, the
BUYER shall have the same right of cancellation upon the same terms as
hereinabove provided.

 

4.                                       DEFINITION
OF PERMISSIBLE DELAY.

 

Delays on
account of such causes as provided for in Paragraph 1 of this Article, but
excluding any other extensions of a nature which under the terms of this
Contract permits postponement of the Delivery Date, shall be understood to be
(and are herein referred to as) permissible delays, and are to be distinguished
from non-permissible delays on account of which the Contract Price is subject to adjustment as
provided for in Article 3 hereof.

 

22

 

5.                                       ACCUMULATED
TIME OF DELAY

 

In the event
that the total accumulated time of all delays including non-permissible as well
as permissible delays, aggregates to One Hundred and Ninety (190) days or more,
then the BUYER may at any time thereafter rescind this Contract in accordance with the provisions of
Article 10 hereof.

 

ARTICLE 9 - WARRANTY OF QUALITY

 

1.                                       GUARANTEE
OF MATERIAL AND WORKMANSHIP

 

The SELLER,
for a period of twelve (12) months following delivery to the BUYER of the
VESSEL, guarantees the VESSEL, her hull (including paints and coats, where
applicable) engine machinery gear and all parts and equipment thereof that are
manufactured or furnished or supplied or installed or applied by the SELLER
and/or its sub-contractors under this Contract including material, equipment
(however excluding any parts for the Vessel which have been supplied by or on
behalf of the BUYER other than if any defects hi respect of such parts arise as
a result of their incorrect or faulty installation or inadequate storage by the
SELLER, the SELLER and/or any sub-contractors appointed under this Contract)
against all defects which are due to faulty design excluding the defects
accepted by both of Parties prior to delivery or defective materials or
defective construction and/or poor workmanship.

 

If the
guarantees given by suppliers and/or subcontractors have a validity in excess
of twelve (12) months, the SELLER will transfer any residual rights in the
guarantees given by any supplier and/or subcontractor to the BUYER at the of
end of the Guarantee period under this Article 9,

 

2.                                       NOTICE
OF DEFECTS

 

The BUYER
shall notify the SELLER in writing, or by telefax, as promptly as possible,
after discovery of any defect or deviations for which a claim is made under
this guarantee. The BUYER’s written notice shall describe the nature and the
extent of the defect. The SELLER shall have no obligation under this guarantee
for any defects discovered after the expiry date of the guarantee, unless notice of
such defects, is received by the SELLER not later than fifteen (15) days after
such expiry date. Telefaxed advice with brief details explaining the nature of
such defect and extent of such defect within fifteen (15) days after such
expiry date and a statement that a claim is forthcoming will be sufficient
compliance with the requirements as to time.

 

3.                                       REMEDY
OF DEFECTS

 

The SELLER
shall remedy at its expense free of charge to the BUYER any defects, against
which the VESSEL or any part of the equipment thereof is guaranteed under this
Article by making all necessary repairs and/or replacement. Such repairs and/or
replacement will be made by the SELLER.

 

The Seller
will provide another 12 months guarantee for the replaced parts, however the
maximum guarantee period will not exceed 18 months after the delivery of the
vessel.

 

However, if it
is impractical to make the repair by the SELLER, and if forwarding by the
SELLER of replacement parts, and materials cannot be accomplished without
impairing or delaying the operation or working of the VESSEL, then, in any such
event, the BUYER may subject to the SELLER’S consent in writing, not to be
unreasonably withheld, cause the necessary repairs or replacements to be made
elsewhere at the discretion of the BUYER, provided that the BUYER shall first
give the SELLER notice in writing by letter, telefax, or telex of the time and
place such repairs will be made and, if the VESSEL, or her operation or working
is not thereby delayed or impaired, the SELLER shall have the right to verify
by its own representative(s) or that of

 

23

 

Classification
Society the nature and extent of the defects complained of. The SELLER shall,
in such cases, promptly advise the BUYER, by telex, after such examination has
been completed, of its acceptance or rejection of the defects as ones that are
subject to the guarantee herein provided. lit all minor cases, the Guarantee Engineer(s),
as hereinafter provide for, will act for and on behalf of the SELLER.

 

Upon the
SELLER’s acceptance of the defects as justifying remedy under this Article, or
upon award of the arbitration so determining, the SELLER shall pay to the BUYER
in freely transferable United States Dollars, whatever actual costs for such
repairs or replacements, including forwarding charges, as either agreed or
awarded by the arbitration tribunal to the BUYER, same not to exceed the costs
of effecting such repairs in a average shipyard in China. Any dispute under
this Article shall he referred to arbitration in accordance with the provisions
of Article 13 hereof.

 

Any
liabilities outstanding at the end of the guarantee period, shall be settled
within thirty (30) days after  the
amounts have been agreed between the parties or in case of disagreement, upon
publication of the Arbitration Award.

 

4.                                       EXTENT
OP THE SELLER’S LIABILITY

 

The SELLER
shall have no obligation and/or liabilities with respect to defects discovered
after the expiration of the period of guarantee specified above.

 

The SELLER
shall be liable to the BUYER for defects and damages caused by any of the
defects specified in Paragraph 1 of this Article provided that such liability
of the SELLER shall be limited to damage, occasioned within the guarantee
period specified in Paragraph 1 above.

 

The SELLER
shall not be obligated to repair, and/or be liable for, damages to the VESSEL
or to any part of the equipment thereof, due to ordinary wear and tear or
caused by the defects other than those specified in  Paragraph I above, nor shall there
be any SELLER’s liability hereunder for defects in the VESSEL, or any part of
the equipment thereof, caused by fire or accidents or mismanagement,
negligence, on the part of the BUYER, its employees or agents including the
VESSEL’s officers, crew and passengers, or any persons on or doing work on the
VESSEL other than the SELLER. its employees, agents or subcontractors.
Likewise, the SELLER shall not be liable for defects in the VESSEL, or the
equipment or any part thereof, due to repairs
or replacement which were made by persons other than the SELLER and/or their
subcontractors and/or their agents and/or their servants.

 

The SELLER
shall have no responsibility or liability for any defects in the VESSEL other
than the defects specified in Paragraph 1, against which the guarantee is given
by the SELLER under this Article. The SELLER shall not be responsible or liable
for any consequential damages, loss of time, loss of profit or earning or
demurrage occasioned to the BUYER by reason of the defects specified in
Paragraph 1 hereof or due to repairs or other works done to the VESSEL to
remedy such defects.

 

The SELLER
shall not be responsible for remedying defects in any part of the VESSEL which
may, subsequent to the delivery of the VESSEL, have been replaced or in any way
repaired by any other contractor (excluding SELLER’s subcontractors, agents or
servants), or for remedying any defects which have developed, or have been
aggravated by acts, omissions or neglect on the part of the BUYER, its servants
or agents or by ordinary wear and tear or by any other circumstances beyond the
control of the SELLER.

 

The Guarantee
provided in this Article and the obligations and the liabilities of the SELLER
hereunder are exclusive and in lieu of and the BUYER hereby waives all other
remedies, warranties, guarantees or liabilities, express or implied, arising by
law or otherwise (including

 

24

 

without limitation
any obligations of the SELLER with respect to fitness, merchantability and
consequential damages) or whether or not occasioned by the SELLER’S negligence.
This Guarantee shall not he extended, altered or varied except by a written
instrument signed by the duly authorized representatives of the SELLER and the
BUYER.

 

The full
benefit of any additional guarantees or warranties given by the SELLERS
subcontractors suppliers or manufacturers if any shall, if requested by the
BUYER, be duly transferred to the BUYER by the SELLER.

 

In case of the
sale of the VESSEL from the BUYERS to a new OWNER during the above stipulated guarantee
period, the SELLER agrees to transfer the remaining guarantee period to the new
owner which shall in no circumstances exceed twelve (12) months from the date
of delivery of the VESSEL to the BUYER provided that this shall not impose any
more obligations and/or liabilities to the SELLER than those contained in the
original guarantee as set out herein.

 

5.                                       GUARANTEE
ENGINEER(S)

 

The SELLER
shall help to arrange one Guarantee Engineer to serve on the VESSEL as the
SELLER’s representative(s) for a period of twelve (12) months, at SELLER’s
option, from the date of delivery of the VESSEL. The BUYER and its employees
shall give such Guarantee Engineer full cooperation in carrying out his duties
as the representative(s) of the SELLER onboard the VESSEL The BUYER shall
accord the Guarantee Engineer(s) the treatment comparable to the VESSEL’s Chief
Engineer, and shall provide him with accommodations and subsistence at no cost
to the SELLER and/or the Guarantee Engineer.

 

The BUYER may
at its option terminate the stay of the Guarantee Engineer before the
completion of one (1) year but in no event earlier than three (3) months after
delivery of the VESSEL, with SELLER’s prior approval which not to be
unreasonably withheld.

 

The BUYER
shall pay to each Guarantee Engineer the sum of United States Dollars two
thousand only (USD 2,000.00) per month to cover his/their miscellaneous
expenses and the BUYER shall pay expense of repatriation of one person to
Fuzhou, the People’s Republic of China by air upon termination of his service,
and also shall pay the expense of his communications with the SELLER when made
in performance of his duties as the Guarantee Engineer and the expenses, if
any, of his medical and hospital care. The BUYER shall indemnify the Guarantee
Engineer for personal injuries, including death and damages to, or loss or
destruction of property of the Guarantee Engineer, if such death, injuries,
damages, loss and/or destruction were caused by gross negligence or wilful
misconduct of the BUYER, its successor(s) and/or assign(s) or its employees and/or
agents.

 

In ease the
BUYER considers that the Guarantee Engineer is unsuitable for the job or is
uncooperative with the VESSEL’s Chief Engineer, then the BUYER shall notify
accordingly the SELLER and the SELLER shall assist to arrange replacement
provided that such replacement is approved by the SELLER ‘s superior
organization and the crews certificates and passports of the replacing engineer(s)
can be procured. Until the replacement in the way set out in the foregoing, no replacement
of the guarantee engineer on aboard should be effected.

 

Pertaining to
the detailed particulars of this paragraph, a detailed Employment Contract will
be executed between the parties hereto upon delivery of the VESSEL.

 

25

 

ARTICLE 10 - CANCELLATION, REJECTION AND RESCISSION BY THE
BUYER

 

1.                                       NOTICE

 

All payments
made by the BUYER prior to the delivery of the VESSEL shall be in  the nature of advance to the
SELLER. In the event the BUYER shall exercise its right of rescission and/or
cancellation of this Contract under and pursuant to any of the provisions of
this Contract specifically permitting the BUYER to do so, then the BUYER shall
notify the SELLER by letter, telefax, or telex and such rescission and/or
cancellation shall be effective as of the date the notice thereof is and/or is
deemed to be received by the SELLER.

 

2.                                       REFUND
BY THE SELLER

 

Upon rescission and/or cancelling of this
Contract by the BUYER pursuant to the provisions hereof; the SELLER shall
refund in United States Dollars immediately to “the BUYER the full amount of
all sums paid by the BUYER and received by the SELLER on account of the VESSEL
together with interest thereon at the rate of live percent (5%).p.a. on the
amounts required to be refunded to the BUYER, computed from the respective
dates on which the relevant sums were paid by the BUYER to the SELLER to the
date of remittance by transfer of such refund net to the BUYER by the SELLER,
unless the SELLER disputes the BUYER’s cancellation and/or rescission by
instituting arbitration within fifteen (15) New York banking days in accordance
with Article 13. However, in the event of total loss as described in Article 12
of this Contract, then, no interest will be refunded on the amount required
herein.

 

If the BUYER’s
cancellation or rescission of this Contract is disputed by the SELLER by
instituting arbitration as aforesaid, then no refund shall be made by the
SELLER, and the BUYER shall not be entitled to demand repayment from Guarantee
Bank under the Refund Guarantee until the arbitration award between the BUYER
and the SELLER or, in case of appeal or appeals, the final court order, which
shall be in favor of the BUYER, declaring the BUYER’s cancellation and/or
rescission justified, is made and delivered to the SELLER by the arbitration
tribunal or final competent English Court having jurisdiction on the dispute.

 

All sums so
refunded shall be paid in freely transferable United States Dollars and the
SELLER undertakes to obtain any necessary exchange control or fiscal consents
or licenses necessary to effect such payment.

 

For the
purpose of this Article, the SELLER shall have delivered to the BUYER, the
irrevocable Refund Guarantee specified in Exhibit ‘B’.

 

Upon such
refund by the SELLER to the BUYER, all obligations, duties and liabilities of
each of the parties hereto to the other under this Contract shall he forthwith
completely discharged.

 

ARTICLE 11 - BUYER’S DEFAULT

 

1.                                       DEFINITION
OF DEFAULT

 

The BUYER
shall be deemed in default of its obligation under the Contract if any of the
following events occurs:

 

(a)                                  The
BUYER fails to pay the Second or Third or Fourth instalment to the SELLER
within five (5) New York banking days after any such instalment become due and
payable under the provisions of Article 2 hereof and provided the BUYER shall
have received the SELLER’S demand for payment and the respective Refund
Guarantee in accordance with Article 2 hereof; or

 

26

 

(b)                                 The
BUYER fails to pay the fifth instalment to the SELLER in accordance with
Paragraph 3(e) and 4(e) of Article 2 hereof; or

 

(c)                                  The
BUYER fails to accept and take delivery of the VESSEL, when the VESSEL is duly
tendered for delivery by the SELLER under the provisions of Article 7 hereof
within seven (7) days from the tendered date- and without any
justifiable reason thereof under this Contract;

 

2.                                       NOTICE
OF DEFAULT

 

If the BUYER
is in default of any instalment of the Contract Price, or in performance if its obligations as
provided hereinabove, the SELLER shall notify the BUYER to that effect by
telex, confirmed in writing, after the date of occurrence of the default as per
Paragraph 1 of this Article and the BUYER shall forthwith acknowledge by telex,
confirmed in writing, to the SELLER that such notification has been received.
In case the BUYER does not give the aforesaid telex acknowledgment to the
SELLER within five (5) New York banking days, it shall be deemed that such
notification has been duly received by the BUYER.

 

3.                                       INTEREST
AND CHARGE

 

If the BUYER
is in default of payment as to any instalment as provided in Paragraph 1 (a)
and/or 1 (b) of this Article, the BUYER shall pay interest on such instalment
at the rate of five percent (5 %) per annum from the due date thereat° the date
of payment to the SELLER of the full amount including all aforesaid interest.
In case the BUYER shall unjustifiably fail to take delivery of the VESSEL when
required to as provided in Paragraph I (c) of this Article, the BUYER shall be
deemed in default of payment of the fifth instalment and shall pay interest
thereon at the same rate as aforesaid from and including the day on which the
VESSEL is tendered for delivery by the SELLER to the date on which payment of
the fifth instalment is received by the SELLER.

 

In any event
of default by the BUYER under 1(a) or 1(b) or 1(c) or 1(d) or 1(e) of this
Article, the BUYER shall also pay all charges and expenses incurred by the
SELLER in consequence of such default.

 

4.                                       DEFAULT
BEFORE DELIVERY OF THE VESSEL

 

(a)                                  If
any default by the BUYER occurs as defined in Paragraph 1 (a) or 1 (b) or (c)
of this Article, the Delivery Date shall, at the SELLER’s option, he postponed
for a period of continuance of such default by the BUYER.

 

(b)                                 If
any such default as defined in Paragraph 1 of this Article committed by the
BUYER continues for a period of fifteen (15) days after receiving the notice
provided in Paragraph 2 of this Article, then, the SELLER shall have all
following rights and remedies:

 

	
  (i)

  	
  The SELLER may,
  at its option, cancel or rescind this Contract, by giving notice of such
  effect to the BUYER by letter or telefax or telex. Upon receipt by the BUYER
  of such notice of cancellation or rescission, all or the BUYER’s supplies and all its
  equipment and machinery shall be kept as a security for the SELLER’s claim;
  and

  
	
   

  	
   

  
	
  (ii)

  	
  In the event of
  such cancellation or rescission of this Contract, the SELLER shall also be
  entitled to retain any installment or installments of the Contract Price paid
  by the BUYER to the SELLER as a security for SELLER’s claim; and

  
	
   

  	
   

  
	
  (iii)

  	
  In addition to
  the above and in the event of such rescission or cancellation, the SELLER
  shall be entitled (but not hound) to exercise and enforce any or all of its

  

 

27

 

rights, powers and
remedies under this contract (including but not limited to the sale of the
VESSEL and application of the proceeds thereof pursuant to Paragraph 5
herebelow) and/or under any or all of the securities provided to the SELLER by
way of security for the BUYER’s obligations hereunder.

 

5.                                       SALE
OF THE VESSEL

 

(a)                                  In
the event of cancellation or rescission of this Contract by the SELLER as above
provided, the SELLER shall have full right and power either to complete or
private sale on such terms and conditions as the SELLER thinks fit without
being answerable for any loss or damage occasioned to the BUYER thereby. In any
case the SELLER will use due diligence in obtaining the best possible sale
price of the VESSEL, which should not be inferior to the actual market value of
the VESSEL at the time of the sate.

 

In the case of sale of the VESSEL, the SELLER
shall give reasonable early written notice by letter, telefax or telex, to the
BUYER and the BUYER shall be entitled to bid for the VESSEL at a public auction
or to make an offer to buy the VESSEL if it receives notice from the SELLER of its
intention to sell it privately.

 

(b)                                 In
the event of the sale of the VESSEL in its completed state. the proceeds of
sale received by the SELLER shall be applied firstly to payment of all expenses
attending such sale and otherwise incurred by the SELLER as a result of the
BUYER’s default, and then to payment of all unpaid installments and/or unpaid
balance of the Contract Price (less the value of the BUYER’s Supplies) and
interest on such installments at the interest rate as specified in the relevant
provisions set out above from the respective due dates thereof to the date of
application.

 

(c)                                  In
the event of the sale of the VESSEL in its incomplete state, the proceeds of
sale received by the SELLER shall be applied firstly to all expenses attending
such sale and otherwise incurred by the SELLER as a result of the BUYER’s
default, and then payment of all costs of construction of the VESSEL (such
costs of construction, as herein mentioned, shall include but are not limited
to all costs of labor and/or prices paid or to be paid by the SELLER for the
equipment and/or technical design and/or materials purchased or to be
purchased, installed and/or to be installed on the VESSEL) less the installments
so retained by the SELLER, and compensation to the SELLER for a reasonable sum
of loss of profit due to the cancellation or rescission of this Contract.

 

(d)                                 In
either of the above events or rescission of this Contract, if the proceeds of
sale exceeds the total of the amounts to which such proceeds are to he applied
as aforesaid, the SELLER shall promptly pay the excess to the BUYER without
interest, provided, however that the amount of such payment to the BUYER shall in  no event exceed the total amount
of installments already paid by the BUYER and the cost of the BUYER’s supplies,
if any.

 

(e)                                  If
the proceeds of sale are insufficient to pay such total amounts payable as
aforesaid, the BUYER shall promptly pay the deficiency ,to the
SELLER upon request.

 

ARTICLE 12 - INSURANCE

 

1.                                       EXTENT
OF INSURANCE COVERAGE

 

From the time
of keel-laying of the first section or block of the VESSEL until the VESSEL is
completed, the SELLER shall, at its own cost and expense, keep the VESSEL and
all machinery, materials, equipment, appurtenances and outfit, delivered by
SELLER for the VESSEL or built

 

28

 

into, or
installed in or upon the VESSEL, fully insured with first class Chinese
insurance company for SELLER’s risk. (Institute Clauses for Builder’s Risks).

 

The insurance
coverage shall be carried up to the date of delivery of the VESSEL, and shall
be in an amount at least equal to the aggregate amount of all payments made by
the BUYER to the SELLER plus the value of the BUYER’s supplies in the custody of the SELLER. The policy referred to
hereinabove shall be taken out in the name of the SELLER and all losses under
such policy shall be payable to the
SELLER.

 

2.                                       APPLICATION
OF RECOVERED AMOUNT.

 

(a)                                  Partial
Loss :

 

In the event
the VESSEL shall be damaged by any insured cause whatsoever prior to acceptance
and delivery thereof by the BUYER and in the further event that such damage
shall not constitute an actual or a constructive total loss of the VESSEL, the
SELLER shall apply the amount recovered under the insurance policy referred to
in Paragraph 1 of this Article to the repair of such damage to the full and
complete satisfaction of the Classification Society, of the regulatory bodies
and other institutions or authorities as described in the  Specifications without additional
expenses to the BUYER and without any notations, recommendations or remarks
whatsoever and the BUYER shall accept the VESSEL under this Contract if fully
repaired and completed in accordance with this Contract and Specifications.

 

(b)                                 Total
Loss

 

However, in
the event that the VESSEL is determined to be an actual or constructive total
loss, the SELLER shall either:

 

(i)                                     By
the mutual agreement between the parties hereto, proceed in accordance with
terms of this Contract, in which case the amount recovered under said insurance
policy shall be applied to the reconstruction and/or repair of the VESSEL’S
damages and/or reinstallation of BUYER’s supplies without additional expenses
to the BUYER, provided the parties hereto shall have first agreed in writing as
to such reasonable extension of the Delivery Date and adjustment of other terms
of this Contract including the Contract Price as may be necessary or the
completion of such reconstruction and/or repair ; or

 

(ii)                                  if
due to whatever reasons the parties fail to agree on the above, then refund
immediately to the BUYER the amount of all installments paid to the SELLER
under this Contract without interests plus the value of the BUYER’S supplies
(if totally lost) whereupon this Contract shall be deemed to be rescinded,
cancelled and automatically terminated, all rights, duties, liabilities and
other obligations of each of the parties to the other shall terminate
forthwith, and the SELLER shall forthwith redeliver to the BUYER any of the
BUYER’s supplies which shall not have become a total loss,

 

Within thirty
(30) days after receiving notice of any damage to the VESSEL constituting an
actual or a constructive total loss, the BUYER shall notify the SELLER in
writing by letter or telefax, or by telex of its agreement or disagreement
under this sub-paragraph. In the event that BUYER fails to so notify the
SELLER, then such failure shall be construed as a disagreement on the part of the BUYER. This Contract shall be
deemed as rescinded and cancelled and the BUYER shaft receive the refund as
hereinabove provided and the provisions hereof shall apply.

 

29

 

3.                                       TERMINATION
OF THE SELLER’S OBLIGATION TO INSURE.

 

The SELLER’S
obligation to insure the VESSEL, hereunder shall cease and terminate forthwith
upon delivery thereof to and acceptance by the BUYER.

 

ARTICLE 13 - DISPUTES AND ARBITRATION

 

1.                                       PROCEEDINGS

 

In the event of any dispute between the parties hereto as to any matter
arising out of or relating to this Contract or any stipulation herein or with
respect thereto which cannot be settled by the parties them selves forthwith,
such dispute shall be resolved by arbitration in London in accordance with the
Laws of England and the LMAA procedure current at the time. Either party may
demand arbitration of any such disputes by giving written notice by letter,
telefax or telex to the other party. Any demand for arbitration by either party
hereto shall state the -name of the arbitrator appointed by such party and
shall also state briefly the question or questions as to which such party is
demanding arbitration. Within twenty (20) days after receipt of notice of such
demand for arbitration, the other party shall in  turn appoint a second arbitrator. The two
arbitrators thus appointed shall have the power, in case of disagreement to
appoint an Umpire. The Arbitrators and the Umpire shall be members of the
London Marine Arbitrators’ Association (“LMAA”).

 

In the event however, that said other party should fail to appoint a
second arbitrator as aforesaid within twenty (20) days following receipt of
notice of-demand of arbitration, it is agreed that such party shall thereby be
deemed to have accepted and appointed as its own arbitrator the one already
appointed by the party demanding arbitration, and the arbitration shall proceed
forthwith before this sole arbitrator. And in the further event that the two
arbitrators appointed respectively by the parties hereto as aforesaid should be
unable to reach agreement on the appointment of the Umpire within twenty (20)
days from the date on which the second arbitrator is appointed, either party &the said two arbitrators may apply to the High
Court of Justice in London, or to the President, for the time being, of the
LMAA. The Arbitration Award issued by the sole Arbitrator or by the two
Arbitrators, or by the Umpire as the case may be, shall be final, conclusive
and binding upon both parties hereto unless appealed by either party in
accordance with the English Laws.

 

The arbitration will he conducted in London, in accordance with and
subject to the provisions of the Arbitration Act 1996, or any statutory modifications or reenactment
thereof, for the time being in force, and in accordance with English law currently in force,

 

2.                                       ALTERNATIVE
ARBITRATION BY AGREEMENT

 

Notwithstanding
the preceding provisions of this Article, h is recognized that in the event of
any dispute or  difference
of opinion arising in regard to the construction of the VESSEL, her machinery
and equipment, or concerning the quality of materials or workmanship thereof or
thereon, such dispute rimy be referred (by mutual agreement of the parties
hereto) to the Classification Society, in such case, the opinion of the
Classification Society shall be final and binding on the parties hereto.

 

3.                                       NOTICE
OF AWARD

 

Notice of any
award being issued shall immediately by given in writing or by telex confirmed
in writing to the SELLER and the BUYER,

 

30

 

4.                                       EXPENSES

 

The
arbitrator(s) shall determine which party shall bear the expenses of the
arbitration or the proportion of such expenses which each party shall bear.

 

5.                                       AWARD
OF ARBITRATION ENTRY INTO COURT

 

In case of
failure by either party to honour the Arbitration Award(s) promptly, a judgment
may be entered in any proper court having jurisdiction thereof.

 

6.                                       ALTERATION
OF DELIVERY TIME

 

In the event
of reference to arbitration of any dispute arising out of matters occurring
prior to delivery of the VESSEL, the BUYER shall not be entitled to extend the
Delivery Date as defined in Article 7 hereof. The Arbitration Tribunal however,
shall be empowered to decide as to what extent if any the Delivery Date is
altered as a result of the arbitration proceedings, if at all,

 

7.                                       SERVICE
AGENTS IN LONDON

 

All notices in
connection with the above Arbitration and any Appeals thereof shall he given by
letter or telefax in accordance with Article 17 hereunder. In addition, the
BUYER hereby irrevocably appoints Messrs. Mr. Riches Consulting Address: Old
Jarretts Farmhouse, Brantridge Lane, Balcombe, West Sussex, RH17 6JR, United Kingdom.

 

ARTICLE 14 - RIGHT OF ASSIGNMENT

 

1.                                       The
Buyer shall not be entitled to assign its rights under this Contract without
the prior written consent of the Seller (such consent not to be unreasonably withheld).
However the Buyer shall be entitled without the prior written consent of the
sellers but with prior written notice to the Sellers, to assign it rights under
this contract in favour of a bank or financial Institution which will finance
part or all of the pre-delivery instalments payable under this Contract as
security for such financing(it being understood for the avoidance of doubt
that:

 

	
  (i)

  	
  Such assignment
  shall be an assignment by way of security in favour of a financier of the
  Buyer and not an assignment by way of transfer in favour of a third party
  purchaser.

  
	
   

  	
   

  
	
  (ii)

  	
  The Seller shall
  not by virtue of such assignment have any additional obligation and/or risk
  other than those existing prior the date of such assignment and

  
	
   

  	
   

  
	
  (iii)

  	
  The Buyer shall
  remain responsible for the Performance of all obligations under this contract
  including but not limited to paying all instalments of the Contract price,
  which shall be approved by this bank or Financial institution.

  

 

2.                                       ASSIGNMENT
WITH EFFECT FROM DELIVERY.

 

Provided that
the BUYER shall remain responsible for the performance of all obligation under
this Contract (including but not limited to paying all installments and
execution of the Protocol of the Delivery and Acceptance) and further that the
SELLER’s right to receive all installments (including the delivery installment)
from the BUYER and all  rights
and benefits hereunder are not in any way prejudiced and the SELLER’s prior
consent in writing, the BUYER shall be entitled to sell its interest in this
Contract to a third party with effect from delivery of the VESSEL and the
SELLER will upon request of the BUYER issue delivery documents in favor of such
third party and deliver the VESSEL to such third party. In such event and upon
delivery of the VESSEL, all rights of the

 

31

 

BUYER shall be
transferred to such third party and the BUYER shall cease to have any right in and under
this Contract,

 

ARTICLE 15 - TAXES AND DUTIES

 

1.                                       TAXES
AND DUTIES INCURRED IN CHINA.

 

The SELLER
shall bear and pay all taxes, duties stamps, dues levies and fees of whatsoever
nature incurred or imposed in China in connection with the execution and/or
performance of this Contract by the SELLER and its sub-contractors, and any payments
to be made hereunder by the BUYER. The SELLER warrants that BUYER’s supplies
for the construction or use of the VESSEL maybe imported into China without
taxes, duties or restrictions, however. The Buyer’s supplies list shall be
approved by the Seller before steel cutting, the amount for Buyer’s supplies to
be less than 10% of contract price and in compliance with the laws of the
People’s Republic of China.

 

2.                                       TAXES
AND DUTIES INCURRED OUTSIDE CHINA.

 

The BUYER
shall bear and pay all taxes, duties, stamps and fees incurred outside China in
connection with execution and/or performance of this Contract by the BUYER,
except for taxes, duties, stamps, dues, levies and fees imposed upon those
items which are to be procured by the SELLER for the construction of the VESSEL
in accordance with the terms of this Contract and the Specifications.

 

ARTICLE 16 - PATENTS, TRADEMARKS AND COPYRIGHT,

 

The machinery
and equipment. of the VESSEL may hear the patent number, trademarks or trade
names of the manufacturers. The SELLER shall defend and save harmless the BUYER
from patent liability or claims of patent infringement of any nature of kind,
including costs and expenses for, or on account of any patented or patentable
invention made or used in the performance of this Contract and also including
cost and expense of litigation, if any.

 

The SELLER’s
indemnity hereunder does not extend to equipment or parts supplied by the BUYER to the
SELLER if any.

 

ARTICLE 17 - NOTICES

 

Any and all
notices and communications by letter,
telefax or telex, in connection with this Contract shall be addressed as
follows

 

	
  To the BUYER

  	
   

  	
  :

  	
   

  	
  Aegean
  Bunkering Services Inc.

  
	
  Address

  	
   

  	
  :

  	
   

  	
  42,
  Hadjikyriakou Avenue, Piraeus 185 38-Greece

  
	
  Telephone
  No.

  	
   

  	
  :

  	
   

  	
  +30210
  4586000

  
	
  Telefax

  	
   

  	
  :

  	
   

  	
  +30210
  4586242

  
	
   

  	
   

  	
   

  	
   

  	
   

  
	
  To the
  SELLER

  	
   

  	
  :

  	
   

  	
  Fujian
  Southeast Shipyard

  
	
  Address

  	
   

  	
  :

  	
   

  	
  7# Jianshe
  Road, Economic Technical Development Zone of Fuzhou, Fujian Province, China

  
	
  Telephone
  No.

  	
   

  	
  :

  	
   

  	
  +86 591
  83985091

  
	
  Telefax

  	
   

  	
  :

  	
   

  	
  +86 591
  83985070

  

 

Any change of
address shall be communicated in writing by registered mail by the party making
such change to the other party and in the event of failure to give such notice
of change, communications addressed to the party at their last known address
shall be deemed sufficient.

 

32

 

Any and all
notices, requests, demands, instructions, advice and communications in connection with this Contract shall
be deemed to be given at and shall become effective from, the time when the
same is delivered to the address of the party to be served, provided, however,
that registered airmail shall be deemed to he delivered ten (10) days after the date of dispatch,
express courier service shall be deemed to be delivered five (5) days after the
date of dispatch, and telex acknowledged by the answer backs shall be deemed to
be delivered upon dispatch.

 

Any and all
notices, communications, Specifications and drawing in connection with this
Contract shall be written in the English language and each party .hereto shall
have no obligation to translate them into any other language.

 

ARTICLE 18 - EFFECTIVE DATE OF CONTRACT.

 

This Contract shall become
effective upon fulfilment of all the following conditions:

 

1.                                       Due execution of
this Contract and the Specifications and maker list; and

 

2.                                       Receipt
by the SELLER of a Performance
Guarantee in the form annexed hereto as Exhibit “A” issued by  AEGEAN BUNKERING SERVICES INC; and

 

3.                                       Receipt by the
BUYER of the Refund Guarantee in  the form
annexed hereto as Exhibit “B” issued by the Guarantee Bank in accordance with
Article 2 Paragraph 7 hereof; and

 

4.                                       Receipt by the
SELLER of the first instalment in accordance with Paragraph 3(a) and 4(a) of
Article 2 of this Contract and

 

5.                                       Receipt by the
SELLER of an assurance letter which agree to provide the finance or loan to the
owner from Euro AAA bank.

 

If due to whatever reason,
any of the above conditions fails to be fulfilled by the June 22, 2007 unless
an extension of time limit is mutually agreed, then this Contract shall be null
and void having no effect whatsoever.

 

ARTICLE 19 - INTERPRETATION

 

1.                                       LAW
APPLICABLE

 

The parties
hereto agree that validity and interpretation of this Contract and of each
Article and part hereof be governed by and interpreted in accordance with the
Laws of England,

 

2.                                       DISCREPANCIES

 

All general
language or requirements embodied in the Specifications are intended to
amplify, explain and implement the requirements of this Contract. However, in
the event that any language or requirements so embodied in the Specifications
permit an interpretation inconsistent with any provision of this Contract, then
in each and. every such event the applicable provisions of this Contract shall
govern. The Specifications and plans are also intended to explain each other
anything shown on the plans and not stipulated in the Specifications or
stipulated in the Specifications and not shown on the plans, shall be deemed
and considered as if embodied in both. In the event of conflict between the
Specifications and plans, the Specifications shall govern,

 

33

 

However, with
regard to such inconsistency or contradiction between this Contract and the
Specifications as may later occur by any change or changes in the
Specifications agreed upon by and among the parties hereto after execution of
this Contract, then such change or changes shall govern.

 

3.                                       DEFINITION

 

(a)                                  In
absence of stipulation of “banking
day(s)” or “business day(s)”, the “day” or “days” shall be taken as “calendar
day” or “calendar days”.

 

(b)                                 “SELLER”
and “BUYER” used in the Specifications shall correspond to “SELLER” and “BUYER”
respectively used in this Contract.

 

4.                                       ENTIRE
AGREEMENT

 

This Contract
contains the entire agreement and understanding between the parties hereto and
supersedes all prior negotiations, representations, undertakings and agreements
on any subject matter of this Contract.

 

5.                                       AMENDMENTS
AND SUPPLEMENTS

 

Any
Supplement, Memorandum of Understanding or Amendment executed after the date
hereof in whatsoever form it may be, relating to this Contract shall be made in
writing and signed by both parties. Such Supplement. Memorandum of Understanding
or Amendment shall be an integral part of this Contract and shall be
predominant over the respective corresponding article/or paragraph of this
Contract.

 

34

 

IN WITNESS
WHEREOF, the parties hereto have caused this Contract to be duly executed on
the day and year first above written,

 

	
  THE BUYER:

  	
  TINOS MARINE
  INC.

  	
  THE SELLER:

  
	
   

  	
   

  	
   

  
	
  Representative

  	
   

  	
  Representative

  
	
   

  	
   

  	
   

  
	
  Signature

  	
   

  	
  Signature

  
	
   

  	
   

  	
   

  
	
  Date

  	
   

  	
  Date

  
	
   

  	
   

  	
   

  
	
  Witness

  	
   

  	
  Witness

  

 

35

 

Understanding
or Amendment shall be an integral part of this Contract and shall be
predominant over the respective corresponding article/or paragraph of this
Contract.

 

IN WITNESS
WHEREOF, the parties hereto have caused this Contract to be duly executed on
the day and year first above written.

 

	
  THE BUYER:

  	
  TINOS MARINE
  INC.

  	
  THE SELLER:

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  Representative:
  

  	
   

  	
  Representative:

  
	
   

  	
   

  	
   

  
	
  Signature:

  	
   

  	
  Signature:

  
	
   

  	
   

  	
   

  
	
  Date:

  	
   

  	
  Date:

  
	
   

  	
   

  	
   

  
	
  Witness:

  	
   

  	
  Witness:

  

 

36

 

Addendum No. 1 to Contract

 

With
reference to the Shipbuilding Contract No.                          
dated 25th of May 2007 (hereinafter called the “CONTRACT”) for one
(I) 3,800 DWT Product Tanker, having the SELLER’s Hull No. DN-3800-    (hereinafter called the -VESSEL”) executed
by and between                           ,
(hereinafter called the -BUYER”) and Fujian Southeast Shipyard (hereinafter
called the “SELLER”), the BUYER and the SELLER hereby mutually agree the
following:

 

1.                                       Last paragraph of Article 18 of the CONTRACT
is amended to read as follows:

 

“If,
due to whatever reason, any of the above conditions fails to be fulfilled by
the le of July 2007 unless an extension of time limit is mutually agreed, then
this Contract shall be null and void having no effect whatsoever.”

 

2.                                       All other terms and conditions of the
CONTRACT shall remain full in force and unaltered.

 

If
there is any discrepancy between the Contract and this Addendum, this Addendum
will prevail.

 

IN
WITNESS WHEREOF, the Buyer and the SELLER have caused this Addendum No. 1 to be
duly executed on this 28th day of June 2007.

 

	
  For
  and on behalf of the BUYER

  	
   

  	
  For
  and on behalf of the SELLER

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  	
   

  	
   

  
	
  .

  	
   

  	
  Fujian
  Southeast ShipyardExhibit 10.1

 

LEHMAN BROTHERS INC.

LEHMAN BROTHERS COMMERCIAL BANK

LEHMAN COMMERCIAL PAPER INC.

745 SEVENTH AVENUE

NEW YORK, NY  10019

 

July 15, 2007

 

IHOP Corp.

CHLH Corp.

450 North Brand Boulevard

Glendale, CA 91203-2306

Attention: 
Tom Conforti

 

$1,950,000,000 First Lien Securitization Bridge
Facilities

$189,000,000 Second Lien Securitization Bridge Loan Facility

Commitment Letter

 

Ladies and Gentlemen:

 

You have advised Lehman Brothers Inc. (“Lehman
Brothers” or the “Sole Arranger”), Lehman Brothers Commercial Bank (“LBCB”)
and Lehman Commercial Paper Inc. (“LCPI;” and together with Lehman
Brothers and LBCB, the “Commitment Parties” or “we” or “us”)
that CHLH Corp. (“Merger Sub”), a newly formed Delaware corporation and
a wholly owned subsidiary of IHOP Corp., a Delaware corporation (the “Borrower”
or “you”), intends to acquire (the “Acquisition”) 100% of the
outstanding capital stock of Applebee’s International, Inc., a Delaware
corporation (the “Target;” and, together with each of its subsidiaries,
the “Acquired Business”) pursuant to an Agreement and Plan of Merger,
dated as of July 15, 2007, by and among the Borrower, Merger Sub and the Target
(together with the schedules and exhibits thereto, the “Acquisition
Agreement”). All references to “dollars” or “$” in this letter
agreement and the attachments hereto (collectively, this “Commitment Letter”)
are references to United States dollars.

 

We understand that the sources of funds required to
fund the Acquisition, to repay all existing indebtedness of the Acquired
Business (the “Refinancing”), other than capital lease obligations to be
agreed, to pay fees and expenses in connection with the Transactions (as
defined below) and to provide for ongoing working capital requirements of the
Borrower and its subsidiaries (including the Acquired Business) following the
Transactions will include:

 

•                       securitization
bridge facilities consisting of (i) a first priority securitization bridge
term loan facility to the Borrower of up to $1,850,000,000 (the “First Lien Securitization
Bridge Term Loan Facility”), together with a securitization bridge
revolving credit facility to the Borrower of $100,000,000, of which no more
than $50,000,000 may be funded on the Closing Date (as hereinafter defined) (plus
an aggregate face amount to be agreed of letters of credit posted thereunder) (the
“First Lien Securitization Bridge Revolving Credit Facility” and,
together with the First Lien Securitization Bridge Term Loan Facility, the “First
Lien Securitization Bridge Facilities”), as described in the Summary of
Terms of First Lien Securitization Bridge Facilities attached hereto as

 

 

Annex I
(the “First Lien Securitization Bridge Term Sheet”), and (ii) a second
priority securitization bridge term loan facility to the Borrower of up to $189,000,000
(the “Second Lien Securitization Bridge Loan Facility” and, together
with the First Lien Securitization Bridge Facilities, the “Securitization
Bridge Facilities”) as described in the Summary of Terms of Second Lien
Securitization Bridge Loan Facility attached hereto as Annex II (the “Second
Lien Securitization Bridge Term Sheet” and, together with the First Lien
Securitization Bridge Term Sheet, the “Securitization Bridge Term Sheets”);
and

 

•                       equity
investments in the Borrower, directly or indirectly, in a form and pursuant to
documentation reasonably satisfactory to the Sole Arranger by one or more
investors in an aggregate amount of not less than $90,000,000 (the “Equity
Financing”).

 

No other financing will be required for the uses
described above. As used herein, the term “Transactions” means the Acquisition,
the initial borrowings under the Securitization Bridge Facilities, the Refinancing,
the Equity Financing and the payments of fees and expenses in connection with
each of the foregoing.

 

It is contemplated that if the Securitization Bridge
Facilities are drawn, then they will be repaid in full (and all commitments
thereunder terminated) upon the consummation of one or more subsequent sales of
securitized debt securities by the Acquired Business or any other subsidiary of
the Borrower (each, a “Securitization”) with the net proceeds of such
Securitizations. Accordingly, completion of a Securitization is not a condition
precedent to the initial funding of the Securitization Bridge Facilities.

 

Commitments.

 

You have requested that Lehman Brothers act as the exclusive
structuring advisor, sole arranger and sole bookrunner for the Securitization
Bridge Facilities, that Lehman Brothers agree to arrange and syndicate the
Securitization Bridge Facilities and that LBCB and LCPI commit to provide or
cause one or more of their respective affiliates to provide the Securitization
Bridge Facilities.

 

Lehman Brothers is pleased to advise you that it is
willing to act as the exclusive structuring advisor, sole arranger and sole
bookrunner for the Securitization Bridge Facilities. LBCB and LCPI are pleased
to advise you of their commitment to provide (either individually, collectively
or through one or more of their affiliates) the entire principal amount of the
Securitization Bridge Facilities (in such capacity, collectively, the “Initial
Securitization Bridge Lender”) upon the terms and subject to the conditions
set forth in this Commitment Letter (collectively, the “Commitments”). By
signing below, you hereby agree that (i) Lehman Brothers will act as the
exclusive structuring advisor, sole arranger and sole bookrunner for the
Securitization Bridge Facilities, (ii) LBCB or LCPI will act as sole and exclusive
administrative agent and collateral agent for the Securitization Bridge
Facilities, (iii) LBCB, LCPI or one of their affiliates will act as sole
and exclusive syndication agent for the Securitization Bridge Facilities and (iv)
each of the Commitment Parties will, in such capacities, perform the duties and
exercise the authority customarily associated with such roles.

 

No other agents, co-agents, arrangers or bookrunners
will be appointed and no Securitization Bridge Lender (as defined below) will
receive compensation with respect to any of the Securitization Bridge
Facilities outside the terms contained herein and in the letter or letters of
even date herewith addressed to you providing, among other things, for certain
fees relating to the Securitization Bridge Facilities (the “Fee Letter”)
in order to obtain its commitment to participate in such Securitization Bridge
Facilities, in each case, unless you and we so agree.

 

2

 

The closing date of the Securitization Bridge
Facilities (the “Closing Date”) shall not occur until the conditions
described in the paragraphs below under the heading “Conditions” have been
satisfied or waived.

 

Syndication
and Cooperation.

 

The Initial Securitization Bridge Lender reserves
the right, prior to or after execution of the Securitization Bridge
Documentation (as defined in Annex III hereto (the “Conditions Annex”))
to syndicate all or a portion of their Commitments to banks, financial
institutions or other institutional lenders identified by the Sole Arranger in
consultation with you (other than certain financial institutions identified in
writing by you to the Sole Arranger prior to the commencement of syndication of
the Securitization Bridge Facilities), that will become parties to the
Securitization Bridge Documentation (the Initial Securitization Bridge Lender
and the banks, financial institutions and other institutional lenders becoming
parties to the Securitization Bridge Documentation, the “Securitization
Bridge Lenders”). Notwithstanding the Initial Securitization Bridge Lender’s
right to syndicate the Securitization Bridge Facilities and receive commitments
with respect thereto, it is understood that any assignment of the Initial
Securitization Bridge Lender’s Commitment prior to the Closing Date shall not
reduce the Initial Securitization Bridge Lender’s obligations to fund its
Commitments in the event the subject assignee shall fail to do so; provided,
that notwithstanding any assignment or participation prior to the Closing Date,
the Sole Arranger shall retain all rights to approve any amendments,
modifications, waivers or other changes to this Commitment Letter.

 

Without limitation of the preceding paragraph, the Sole
Arranger will, in consultation with you, manage all aspects of the syndication
of the Securitization Bridge Facilities, including selection of additional
Securitization Bridge Lenders in consultation with you (other than certain
financial institutions identified in writing by you to the Sole Arranger prior
to the commencement of syndication of the Securitization Bridge Facilities),
determination of when the Sole Arranger will approach potential additional
Securitization Bridge Lenders, any naming rights (except as set forth above),
the final allocations of the Commitments in respect of the Securitization
Bridge Facilities among the additional Securitization Bridge Lenders and the
amount and distribution of fees among the Securitization Bridge Lenders. To
assist the Sole Arranger in its syndication efforts, you agree that you will,
and will cause your representatives and advisors to, and will use commercially
reasonable efforts to cause the Acquired Business and its representatives and
advisors to, (a) prepare and provide all financial and other information
as we may reasonably request with respect to you, your existing securitization
facility, the Acquired Business and the Transactions, (b) use commercially
reasonable efforts to ensure that such syndication efforts benefit from existing
lending relationships of the Borrower and the Acquired Business, (c) make
available to prospective Securitization Bridge Lenders your senior management
and use commercially reasonable efforts to make available the senior management
of the Acquired Business, both at times and in locations to be mutually agreed
upon, (d) host, with the Sole Arranger, one or more meetings (which
meetings may be a teleconference) with prospective Securitization Bridge
Lenders under each of the Securitization Bridge Facilities, (e) assist the
Sole Arranger in the preparation of one or more confidential information
memoranda and other marketing materials to be used in connection with the
syndication of each of the Securitization Bridge Facilities which are customary
for syndication of such facilities, (f) use commercially reasonable
efforts to obtain prior to the commencement of the syndication process (as
measured from the date of receipt of marketing materials satisfactory to the
Sole Arranger), at your expense, and to the extent deemed necessary by the Sole
Arranger in its sole discretion, monitored public ratings of the Borrower and
the Securitization Bridge Facilities from Moody’s Investors Service, Inc. (“Moody’s”)
and Standard & Poor’s Ratings Group (“S&P”), and to participate
in the process of securing such ratings, including having your senior
management, and using commercially reasonable efforts to have senior management
of the Acquired Business, meet with such rating agencies and (g) use
commercially reasonable efforts to ensure that there is a period of not less
than fifteen consecutive

 

3

 

business days between the date of completion of the
materials described in clause (e) above and the Closing Date to market and
syndicate the Securitization Bridge Facilities; provided, however,
that notwithstanding anything in this clause (g) to the contrary, your
compliance with this clause (g) shall not be deemed to require that the Closing
Date occur later than the date that is two business days after the date of
completion of the “Bridge Marketing Period” (as defined in the Acquisition
Agreement as in effect on the date hereof).

 

Information.

 

You hereby represent that (a) all information
(other than financial projections (the “Projections”), general economic
and industry data and other forward looking statements) that has been or will
be made available to the Initial Securitization Bridge Lender by or on behalf
of you in connection with the Transactions (the “Information”) (to your
knowledge, to the extent of information relating to the Acquired Business), when
taken as a whole, is, and in the case of Information made available after the
date hereof will be, when furnished, true and correct in all material respects
and does not and will not, when furnished, taken as a whole with all other
Information, contain any untrue statement of a material fact or omit to state a
material fact necessary to make the statements contained therein, in light of
the circumstances under which such statements are made, not materially misleading
and (b) the Projections that have been or will be made available to the Commitment
Parties by or on behalf of you in connection with the Transactions have been
or, in the case of Projections made available after the date hereof, will be
prepared in good faith based upon assumptions believed by you to be reasonable
at the time made, it being understood that projections are, by their nature,
inherently uncertain and actual results may vary materially from the
Projections. You agree that if at any time prior to the Closing Date any of the
representations in the preceding sentence would, to the best of your knowledge,
be incorrect in any material respect if the Information or Projections were
being furnished, and such representations were being made, at such time, you
will supplement the Information and the Projections so that such
representations will be correct in all material respects under those
circumstances.

 

You hereby acknowledge that (a) the Sole Arranger
will make available Information and Projections (collectively, “Borrower
Materials”) to the proposed syndicate of Securitization Bridge Lenders by
posting the Borrower Materials on IntraLinks or another similar electronic
system (the “Platform”) and (b) certain of the proposed Securitization
Bridge Lenders may be “public-side” Lenders (i.e., Lenders that do not wish to
receive material non-public information with respect to the Borrower or the
Target or any of their respective securities) (each, a “Public Lender”).
You hereby agree that, so long as the Borrower or the Target is the issuer of
any outstanding debt or equity securities that are registered or issued
pursuant to a private offering or are actively contemplating issuing any such
securities, (w) you will, and will use commercially reasonable efforts to cause
the Acquired Business to, identify that portion of the Borrower Materials that
may be distributed to the Public Lenders and that all Borrower Materials that
are to be made available to Public Lenders shall be clearly and conspicuously
marked “PUBLIC” which, at a minimum, shall mean that the word “PUBLIC” shall
appear prominently on the first page thereof; (x) by marking Borrower Materials
“PUBLIC,” you shall be deemed to have authorized the Sole Arranger and the
proposed Securitization Bridge Lenders to treat such Borrower Materials as not
containing any material non-public information with respect to you or the
Target or any of your or their respective securities for purposes of United
States federal and state securities laws, it being understood that certain of
such Borrower Materials may be subject to the confidentiality requirements of
the definitive credit documentation; (y) all Borrower Materials marked “PUBLIC”
are permitted to be made available through a portion of the Platform designated
“Public Investor;” and (z) the Sole Arranger shall be entitled to treat any
Borrower Materials that are not marked “PUBLIC” as being suitable only for
posting on a portion of the Platform not designated “Public Investor.”  Notwithstanding the foregoing, you shall be
under no obligation to mark any Borrower Materials “PUBLIC.”

 

4

 

Fees and
Expenses.

 

As consideration for the Commitments of the Initial
Securitization Bridge Lender hereunder with respect to the Securitization
Bridge Facilities, the agreement of the Sole Arranger to structure, arrange and
syndicate the Securitization Bridge Facilities, you agree to pay, or cause to
be paid, to the Initial Securitization Bridge Lender the fees and expenses set
forth in the Securitization Bridge Term Sheets and the Fee Letter on the dates
set forth in the Securitization Bridge Term Sheets and the Fee Letter.

 

Conditions.

 

The several commitments of the Initial
Securitization Bridge Lender and obligations of the Commitment Parties
hereunder with respect to each of the Securitization Bridge Facilities are
subject to the following conditions: (i) there not having occurred, since the
date of the Acquisition Agreement, a Material Adverse Effect (as defined in the
Acquisition Agreement)
and (ii) the other conditions set forth in either Securitization
Bridge Term Sheet under the heading “Conditions to Initial Borrowing” or in the
Conditions Annex having been satisfied or waived.

 

Notwithstanding anything in this Commitment Letter,
the Securitization Bridge Term Sheets, the Conditions Annex, the Fee Letter,
the Securitization Bridge Documentation or any other letter agreement or other
undertaking concerning the financing of the Transactions to the contrary, (i) the
only representations, the making of which shall be a condition to availability
of the Securitization Bridge Facilities on the Closing Date, shall be (A) the
representations and warranties made by the Target in the Acquisition Agreement
material to the interests of the Securitization Bridge Lenders, and only to the
extent any breach of such representations and warranties shall give you the
right to terminate your obligations under the Acquisition Agreement, and (B)
the Specified Representations (as defined below) and (ii) the terms of the
Securitization Bridge Documentation shall be in a form such that they do not
impair availability of the Securitization Bridge Facilities on the Closing Date
if the conditions described or referred to under this heading “Conditions” are
satisfied (it being understood that, to the extent any Collateral (as defined
in the Annexes hereto) (other than (x) the pledge and perfection of the
security interests in capital stock of U.S. subsidiaries held by the Borrower
or any Guarantor, (y) other assets pursuant to which a lien may be
perfected by the filing of a financing statement under the Uniform Commercial
Code and (z) owned intellectual property registered in the U.S. Copyright
Office or the U.S. Patent and Trademark Office pursuant to which a lien may be
perfected by the filing of an appropriate notice of security interest in such
office) is not provided on the Closing Date after your use of commercially
reasonable efforts to do so, the delivery of such Collateral shall not
constitute a condition precedent to the availability of the Securitization
Bridge Facilities on the Closing Date but shall be required to be delivered
after the Closing Date pursuant to arrangements to be mutually agreed). Without
limiting the foregoing, the Securitization Bridge Documentation shall not contain
any conditions precedent to the initial borrowing other than the conditions
precedent described or referred to under this heading “Conditions.”  For purposes hereof, “Specified
Representations” means the representations and warranties with respect to
the Borrower and its subsidiaries and the Acquired Business set forth in the
Securitization Bridge Term Sheets relating to due authorization, execution,
delivery and enforceability of the Securitization Bridge Documentation (if
applicable), corporate power and authority, Federal Reserve margin regulations,
the Investment Company Act and validity and perfection of security interests in
the Collateral (but subject to the parenthetical at the end of clause (ii) of
the previous sentence).

 

Clear Market.

 

From the date of this Commitment Letter until the
earlier of (x) 365 days after the Closing Date and (y) the repayment
in full of the Securitization Bridge Facilities and the termination of

 

5

 

the commitments thereunder, you will ensure that no
debt or equity financing (other than (i) the Securitization Bridge
Facilities, any Securitization and any other debt or equity financing used to
refinance the Securitization Bridge Facilities and (ii) any purchase money
indebtedness, trade payables, capital leases or letters of credit issued to
support insurance policies, in each case in the clause (ii), incurred in the
ordinary course of business) and no debt securities offering for the Borrower
or any of its subsidiaries, and, prior to the Closing Date, will use
commercially reasonable efforts to ensure than no debt or equity financing for the
Acquired Business or any of its subsidiaries, is announced, syndicated or
placed without the prior written consent of the Sole Arranger if such
financing, syndication or placement would have, in the reasonable judgment of the
Sole Arranger, a materially detrimental effect upon such syndication; provided,
that the foregoing provision shall not apply to any indebtedness permitted to
be incurred by the Acquired Business pursuant to the Acquisition Agreement as
in effect on the date hereof.

 

You also agree that from the date of this Commitment
Letter until the Closing Date, neither you nor any of your subsidiaries will
issue, incur or otherwise become liable for any additional indebtedness under
the provisions of the documentation governing the Borrower’s existing
securitization facility (the “IHOP Securitization”) without the prior
written consent of the Sole Arranger.

 

Indemnity.

 

The Borrower and Merger Sub
hereby jointly and severally agree to indemnify and hold harmless the Initial
Securitization Bridge Lender, the Sole Arranger, the other Securitization
Bridge Lenders and each of their respective affiliates and all their respective
officers, directors, partners, trustees, employees, shareholders, advisors,
agents, attorneys and controlling persons and each of their respective heirs,
successors and assigns (each, an “Indemnified Person”) from
and against any and all losses, claims, damages and liabilities to which any
Indemnified Person may become subject arising out of or in connection with this
Commitment Letter, the Securitization Bridge Facilities, the use of the
proceeds therefrom, the Acquisition, any of the other transactions
contemplated hereby or any claim, litigation, investigation or
proceeding relating to any of the foregoing, regardless of whether any
Indemnified Person is a party thereto, and to reimburse each Indemnified Person
promptly upon demand for all documented reasonable legal and other expenses
reasonably incurred by it in connection with investigating, preparing to defend
or defending, or providing evidence in or preparing to serve or serving as a
witness with respect to, any lawsuit, investigation, claim or other proceeding
relating to any of the foregoing (including, without limitation, in connection
with the enforcement of the indemnification obligations set forth herein); provided,
however, that no Indemnified Person will be entitled to indemnity
hereunder in respect of any loss, claim, damage, liability or expense (i) to
the extent that it resulted from the gross negligence, willful misconduct or
bad faith of, or material breach of this Commitment Letter by, such Indemnified
Person or any of its related parties as determined by a court of competent
jurisdiction or (ii) arising out of or in connection with any claim,
litigation, investigation or proceeding that does not involve an act or
omission of you or any of your affiliates and that is brought by an Indemnified
Person against any other Indemnified Person. In no event will any Indemnified
Person be liable on any theory of liability for indirect, special or
consequential damages, lost profits or punitive damages as a result of any
failure to fund any of the Securitization Bridge Facilities contemplated hereby
or otherwise in connection with the Transactions or the Securitization Bridge
Facilities. No Indemnified Person will be liable for any damages arising from
the use by others of information, projections or other materials sent through
electronic, telecommunications or other information transmission systems,
except to the extent such damages resulted directly from the gross negligence,
willful misconduct or bad faith of, or material breach of this Commitment
Letter by, such Indemnified Person or any of its related parties as determined
by a court of competent jurisdiction.

 

The Borrower and Merger Sub
each further agrees that, without the prior written consent of each of the
Commitment Parties, which consent will not be unreasonably withheld or delayed,
none of

 

6

 

them will enter into any settlement of a lawsuit,
claim or other proceeding arising out of this Commitment Letter or the
transactions contemplated by this Commitment Letter unless such settlement
includes an explicit and unconditional release from the party bringing such
lawsuit, claim or other proceeding of all Indemnified Persons.

 

The Borrower, Merger Sub and each Commitment Party
agree that if any indemnification or reimbursement sought pursuant to this
Commitment Letter is judicially determined to be unavailable for a reason
other than the gross negligence, willful misconduct or bad faith of, or
material breach of this Commitment Letter by, such Indemnified Person, then you
will contribute to the amount paid or payable by such Commitment Party as a
result of such losses, claims, damages, liabilities and expenses for which such
indemnification or reimbursement is held unavailable (i) in such
proportion as is appropriate to reflect the relative benefits to you, on the
one hand, and such Commitment Party, on the other hand, in connection with the
transactions to which such indemnification or reimbursement relates, or
(ii) if the allocation provided by clause (i) above is judicially
determined not to be permitted, in such proportion as is appropriate to reflect
not only the relative benefits referred to in clause (i) but also the
relative fault of you, on the one hand, and such Commitment Party, on the other
hand, as well as any other equitable considerations;  provided,
however, that upon execution of the Securitization Bridge Documentation
the indemnification provisions contained therein shall supersede those
contained herein.

 

Confidentiality.

 

This Commitment Letter is furnished for your
benefit, and may not be relied on by any other person or entity. Neither the
existence of this Commitment Letter, the Securitization Bridge Term Sheets, the
Conditions Annex, the Fee Letter, nor any of their contents may be disclosed by
you or any of your affiliates, directly or indirectly, to any other person,
except that such existence and contents (including this Commitment Letter, the
Securitization Bridge Term Sheets, the Conditions Annex and the Fee Letter) may
be disclosed (i) as may be compelled in a judicial or administrative
proceeding or as otherwise required by law or the Securities and Exchange
Commission or other governmental authority having jurisdiction over you or any
such affiliate (in which case you agree, to the extent permitted by law and
reasonably practicable, to inform the Sole Arranger promptly thereof), (ii) to your
directors, officers, employees, affiliates, advisors (including legal advisors)
and agents, in each case on a confidential and “need-to-know” basis and only in
connection with the transactions contemplated hereby and (iii) in
connection with any dispute or adversarial process related to this Commitment
Letter, and as reasonably required for syndication. In addition, this
Commitment Letter, the Securitization Bridge Term Sheets, the Conditions Annex
and the Fee Letter (but only with appropriate redactions to the Fee Letter to
delete all fee amounts) may be disclosed to the Acquired Business and its
directors, officers, employees, advisors (including legal advisors) and agents
on a confidential and “need-to-know” basis and only in connection with the
transactions contemplated hereby. Furthermore, this Commitment Letter and the
Fee Letter (but only with appropriate redactions to the Fee Letter to delete
all fee amounts) may be disclosed by you to any ratings agencies or any
monoline insurance company or other provider of credit enhancement, in each
case, on a confidential and “need-to-know” basis and only in connection with
the transactions contemplated hereby.

 

Other Services.

 

You acknowledge that the Initial Securitization
Bridge Lender, the Sole Arranger and their respective affiliates (the term “Initial
Securitization Bridge Lender” or “Sole Arranger” as used below in this
paragraph being understood to include such affiliates) may be providing debt
financing, equity capital or other services (including financial advisory
services) to other companies in respect of which you, the Acquired Business or any
of your or the Acquired Business’ respective subsidiaries may have conflicting
interests regarding the transactions described herein and otherwise. The Initial

 

7

 

Securitization Bridge Lender and the Sole Arranger
will not use confidential information obtained from you by virtue of the
transactions contemplated by this Commitment Letter or its other relationships
with you or the Acquired Business in connection with the performance by the
Initial Securitization Bridge Lender or the Sole Arranger of services for other
companies, and the Initial Securitization Bridge Lender and the Sole Arranger will
not furnish any such information to other companies. The Sole Arranger and its
affiliates will use all confidential information provided to them or such
affiliates by or on behalf of you or the Acquired Business hereunder solely for
the purpose of providing the services which are the subject of this Commitment
Letter and shall treat confidentially all such information. You also
acknowledge that the Initial Securitization Bridge Lender and the Sole Arranger
shall not have any obligation to use in connection with the transactions
contemplated by this Commitment Letter, or to furnish to you, the Acquired
Business or any of your or the Acquired Business’ respective affiliates,
confidential information obtained from other companies. You further acknowledge
that the Sole Arranger is a full service securities firm and it and the Initial
Securitization Bridge Lender may from time to time effect transactions, for
their own or their affiliates’ account or the account of customers, and hold
positions in loans, securities or options on loans or securities of the
Borrower, Merger Sub or any of their respective affiliates and other companies
that may be the subject of the transactions contemplated by this Commitment
Letter.

 

Governing Law,
Etc.

 

This Commitment Letter and the commitment of the
Securitization Bridge Lenders shall not be assignable by you without the prior
written consent of the Commitment Parties, and any purported assignment without
such consent shall be void; provided, however, that you may
assign your rights and delegate your obligations hereunder to one or more
affiliates of the Borrower controlled by the Borrower and formed for the
purpose of effecting the Transactions. This Commitment Letter may not be
amended or any provision hereof waived or modified except by an instrument in
writing signed by each Commitment Party and you. This Commitment Letter may be
executed in any number of counterparts, each of which shall be an original and
all of which, when taken together, shall constitute one agreement. Delivery of
an executed counterpart of a signature page of this Commitment Letter by
facsimile transmission or electronic photocopy (i.e., “pdf”) shall be effective
as delivery of a manually executed counterpart of this Commitment Letter. Headings
are for convenience only. This Commitment Letter is intended to be for the
benefit of the parties hereto and is not intended to confer any benefits upon,
or create any rights in favor of, any person other than the parties hereto, the
Securitization Bridge Lenders and, with respect to the indemnification provided
under the heading “Indemnity,” each Indemnified Person. This
Commitment Letter shall be governed by, and construed in accordance with, the
laws of the State of New York. Any right to trial by jury with respect to
any claim or action arising out of this Commitment Letter is hereby waived. The
parties hereto hereby submit to the non-exclusive jurisdiction of the federal
and New York State courts located in The City of New York (and
appellate courts thereof) in connection with any dispute related to this
Commitment Letter or any of the matters contemplated hereby. The parties hereto
irrevocably and unconditionally waive any objection to the laying of such venue
of any such suit, action or proceeding brought in any such court and any claim
that any such suit, action or proceeding has been brought in an inconvenient
forum. A final judgment in any such suit, action or proceeding brought in any
such court may be enforced in any other courts to whose jurisdiction the party
subject to such judgment is or may be subject by suit upon judgment.

 

Compliance and
Patriot Act.

 

We hereby notify you that pursuant to the
requirements of the USA Patriot Act, Title III of Pub. L. 107-56 (signed
into law October 26, 2001) (the “Patriot Act”), the Commitment
Parties and the Securitization Bridge Lenders are required to obtain, verify
and record information that identifies the Borrower, which information includes
the name, address and tax identification number of the Borrower

 

8

 

and other information regarding the Borrower that
will allow such Commitment Party or such Securitization Bridge Lender to identify
the Borrower in accordance with the Patriot Act. This notice is given in
accordance with the requirements of the Patriot Act and is effective as to the Commitment
Parties and the Securitization Bridge Lenders. The Borrower and each of the
Guarantors (as defined in the Annexes hereto) agree to provide, at least five
days prior to the Closing Date, the documentation and other information to the
Administrative Agent (as defined in the Annexes hereto) that is required by
regulatory authorities under applicable “know your customer” and
anti-money-laundering rules and regulations, including, without limitation, the
Patriot Act.

 

*              *              *

 

Please indicate your acceptance of the terms hereof
and of the Securitization Bridge Term Sheets, the Conditions Annex and the Fee
Letter by returning to us executed counterparts of this Commitment Letter and
the Fee Letter not later than 5:00 p.m., New York City time, on
July 16, 2007. This Commitment Letter and the agreement of the Commitment
Parties to provide the services described herein will automatically expire at
such time if we have not received such executed counterparts of this Commitment
Letter and the Fee Letter in accordance with the preceding sentence. If you do
so execute and deliver to the Commitment Parties, this Commitment Letter and
the Fee Letter, the Initial Securitization Bridge Lender agrees to hold its Commitments
available for you until the earliest of (i) the termination of the Acquisition
Agreement, (ii) the consummation of the Acquisition without utilization of the
Securitization Bridge Facilities and (iii) 11:59 p.m., New York City
time, on the Outside Date (as defined in the Acquisition Agreement), at which
time the Commitments shall expire. The compensation, expense reimbursement,
confidentiality, indemnification and governing law and forum provisions hereof
and in the Securitization Bridge Term Sheets and the Fee Letter shall survive
termination of this Commitment Letter (or any portion hereof) or the
commitments of the Securitization Bridge Lenders hereunder; provided, that in the event the Securitization Bridge Documentation
is executed, the expense reimbursement and indemnification provisions hereof
shall be terminated and superseded by the expense reimbursement and
indemnification provisions in the Securitization Bridge Documentation. The
provisions under the headings “Syndication and Cooperation” and “Clear Market”
above shall survive the execution and delivery of the Securitization Bridge
Documentation.

 

9

 

We are pleased to have been given the opportunity to
assist you in connection with the financing for the Transactions.

 

	
  

  	
  Very truly yours,

  
	
   

  	
   

  
	
   

  	
  LEHMAN BROTHERS COMMERCIAL BANK

  
	
   

  	
   

  
	
   

  	
   

  
	
   

  	
  By:

  	
  /s/ George Janes

  
	
   

  	
   

  	
  Name: George Janes

  
	
   

  	
   

  	
  Title: Chief Credit Officer

  
	
   

  	
   

  
	
   

  	
   

  
	
   

  	
  LEHMAN BROTHERS INC.

  
	
   

  	
   

  
	
   

  	
   

  
	
   

  	
  By:

  	
  /s/ Laurie B. Perper

  
	
   

  	
   

  	
  Name: Laurie B. Perper

  
	
   

  	
   

  	
  Title: Senior Vice President

  
	
   

  	
   

  
	
   

  	
   

  
	
   

  	
  LEHMAN COMMERCIAL PAPER INC.

  
	
   

  	
   

  
	
   

  	
   

  
	
   

  	
  By:

  	
  /s/ Laurie B. Perper

  
	
   

  	
   

  	
  Name: Laurie B. Perper

  
	
   

  	
   

  	
  Title: Senior Vice President

  

 

Signature
page to Commitment Letter

 

 

	
  Accepted and agreed to as of

  	
   

  
	
  the date first written above:

  	
   

  
	
   

  	
   

  
	
  IHOP CORP.

  	
   

  
	
   

  	
   

  
	
   

  	
   

  
	
  By:

  	
  /s/ Thomas Conforti

  	
   

  
	
   

  	
  Name: Thomas Conforti

  	
   

  
	
   

  	
  Title: Chief Financial Officer

  	
   

  
	
   

  	
   

  
	
   

  	
   

  
	
  CHLH CORP.

  	
   

  
	
   

  	
   

  
	
   

  	
   

  
	
  By:

  	
  /s/ Thomas Conforti

  	
   

  
	
   

  	
  Name: Thomas Conforti

  	
   

  
	
   

  	
  Title: Chief Financial Officer

  	
   

  

 

Signature
page to Commitment Letter

 

 

ANNEX I

 

SUMMARY OF TERMS OF FIRST LIEN SECURITIZATION
BRIDGE FACILITIES

 

Capitalized terms used herein and not
otherwise defined shall have the meanings ascribed to such terms in the
Commitment Letter, to which this summary is attached.

 

	
  Borrower:

  	
   

  	
  IHOP Corp.

  
	
   

  	
   

  	
   

  
	
  Exclusive
  Structuring Advisor:

  	
   

  	
  Lehman
  Brothers Inc. (“Lehman Brothers”).

  
	
   

  	
   

  	
   

  
	
  Sole
  Arranger and Sole

  	
   

  	
   

  
	
  Bookrunner:

  	
   

  	
  Lehman Brothers.

  
	
   

  	
   

  	
   

  
	
  First
  Lien

  	
   

  	
   

  
	
  Securitization Bridge Lenders:

  	
   

  	
  The Initial Securitization Bridge Lender or a
  syndicate of banks, financial institutions and other entities, arranged by
  the Sole Arranger (collectively, the “First Lien Securitization Bridge
  Lenders”); provided that any such syndication shall comply with
  the terms and conditions set forth in the Commitment Letter.

  
	
   

  	
   

  	
   

  
	
  Administrative
  Agent and

  	
   

  	
   

  
	
  Collateral Agent:

  	
   

  	
  Lehman Brothers Commercial Bank (“LBCB”) or
  Lehman Commercial Paper Inc. (“LCPI”).

  
	
   

  	
   

  	
   

  
	
  Swing Line Lender:

  	
   

  	
  LBCB or LCPI.

  
	
   

  	
   

  	
   

  
	
  Letter of Credit Issuing Entity:

  	
   

  	
  To be determined.

  
	
   

  	
   

  	
   

  
	
  Syndication Agent:

  	
   

  	
  LBCB, LCPI or one of their affiliates.

  
	
   

  	
   

  	
   

  
	
  Type and Amount of Facilities:

  	
   

  	
  First Lien Securitization Bridge Term Loan Facility:

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  A one-year term securitization bridge term loan
  facility to be made available to the Borrower in U.S. dollars in the manner
  provided herein (the “First Lien Securitization Bridge Term Loan Facility”;
  and the loans made under the First Lien Securitization Bridge Term Loan
  Facility, the “First Lien Securitization Bridge Term Loans”) in an
  aggregate principal amount of up to $1,850,000,000.

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  First Lien Securitization
  Bridge Revolving Credit Facility:

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  A one-year revolving
  credit facility to be made available to the Borrower in the manner provided
  herein (the “First Lien Securitization Bridge Revolving Credit Facility”,
  and the loans thereunder, the “Securitization Bridge Revolving Credit
  Loans”) with aggregate commitments (the “Securitization Bridge
  Revolving

  

 

I-1

 

	
   

  	
   

  	
  Credit Commitments”) of $100,000,000. Each First Lien
  Securitization Bridge Lender holding a Securitization Bridge Revolving Credit
  Commitment shall be referred to herein as a “First Lien Securitization
  Bridge Revolving Credit Lender.”

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  The First Lien
  Securitization Bridge Term Loan Facility and the First Lien Securitization
  Bridge Revolving Credit Facility are referred to herein collectively as the “First
  Lien Securitization Bridge Facilities” and the First Lien Securitization
  Bridge Term Loans and the Securitization Bridge Revolving Credit Loans are
  referred to herein collectively as the “First Lien Securitization Bridge
  Loans”.

  
	
   

  	
   

  	
   

  
	
  Purpose:

  	
   

  	
  Proceeds of the First Lien Securitization Bridge
  Term Loan Facility will be used on the Closing Date (as defined below) to
  finance a portion of the Acquisition, to effect the Refinancing, to fund one
  or more interest reserve accounts and to pay fees and expenses in connection
  therewith. The First Lien Securitization Bridge Revolving Credit Facility
  will be used by the Borrower for working capital and general corporate
  purposes.

  
	
   

  	
   

  	
   

  
	
  Closing Date:

  	
   

  	
  The date of consummation of the Acquisition and the
  initial funding under the First Lien Securitization Bridge Facilities.

  
	
   

  	
   

  	
   

  
	
  Definitive Documentation:

  	
   

  	
  The terms of the definitive documentation governing
  the First Lien Securitization Bridge Facilities (the “First Lien
  Securitization Bridge Documentation”) shall be consistent with the terms
  and conditions of the Commitment Letter.

  
	
   

  	
   

  	
   

  
	
  Maturity Dates:

  	
   

  	
  First Lien Securitization Bridge Term Loan Facility: First anniversary of the Closing Date
  (“Initial Maturity Date”).

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  First Lien Securitization Bridge Revolving Credit
  Facility:
  Initial Maturity Date.

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  If any First Lien Securitization Bridge Term Loans
  (the “Senior Initial Loans” and, together with the Second Lien Initial
  Loans, the “Initial Loans”) have not been paid in full on or prior to
  the date that is one year following the Closing Date (the “Conversion Date”),
  subject to the conditions outlined below under “Conditions to Conversion of
  Senior Initial Loans,” such Senior Initial Loans shall be converted into a
  senior term

  

 

I-2

 

	
   

  	
   

  	
  loan (each, a “Senior
  Term Loan”) maturing on the fourth anniversary of the Conversion Date
  (the “Senior Term Loan Maturity Date”). Other than the maturity date,
  all other terms and conditions set forth herein applicable to the First Lien
  Securitization Bridge Facilities shall apply to the Senior Term Loan.

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  If the Senior Initial
  Loans are converted into Senior Term Loans as provided above, then the
  maturity date of the First Lien Securitization Bridge Revolving Credit
  Facility will be extended to the Senior Term Loan Maturity Date.

  
	
   

  	
   

  	
   

  
	
  Conditions to Conversion
  of

  	
   

  	
   

  
	
  Senior Initial Loans:

  	
   

  	
  On the Conversion Date,
  unless a payment or bankruptcy default has occurred and is continuing under
  the First Lien Securitization Bridge Documentation, the Senior Initial Loans
  shall, upon payment of the Conversion Fee (as defined in the Fee Letter), be
  converted into Senior Term Loans.

  
	
   

  	
   

  	
   

  
	
  Availability:

  	
   

  	
  First Lien Securitization
  Bridge Term Loan Facility: A single drawing may be
  made on the Closing Date of up to the full amount of the First Lien
  Securitization Bridge Term Loan Facility; provided, that if
  (i) securitized debt securities (the “Additional IHOP Securitization
  Securities”) under the IHOP Securitization are issued on the Closing
  Date, the amount of the First Lien Securitization Bridge Term Loan Facility
  shall be reduced by an amount equal to the greater of (A) the aggregate
  amount of gross cash proceeds received from the issuance of such Additional
  IHOP Securitization Securities and (B) * (ii) a Securitization with
  respect to the Acquired Business (an “Applebee’s Securitization”) is
  consummated on the Closing Date, the amount of the First Lien Securitization
  Bridge Term Loan Facility shall be reduced by *, (iii) the Borrower or any of
  its subsidiaries receives proceeds from the unwind of the interest rate
  derivative described in item 5 of Annex III or any replacement thereof on or
  prior to the Closing Date, the amount of the First Lien Securitization Bridge
  Term Loan Facility shall be reduced by the aggregate gross proceeds of such
  unwind or (iv) the Borrower or any of its subsidiaries receives proceeds from
  any sale-leaseback transaction on or prior to the Closing Date, the amount of
  the First Lien Securitization Bridge Term Loan Facility shall be reduced by
  the aggregate net proceeds of such sale-leaseback transaction.

  

 

__________________

*  This information has been
omitted based on a request for confidential treatment. The omitted portions have
been separately filed with the Securities and Exchange Commission.

 

I-3

 

	
   

  	
   

  	
  First Lien
  Securitization Bridge Revolving Credit Facility:
  Borrowings may be made (i) on the Closing Date in an aggregate amount not
  to exceed $50,000,000 (plus an aggregate face amount to be agreed of letters
  of credit posted thereunder) and (ii) at any time after the Closing Date
  to but excluding the business day preceding the maturity date of the First
  Lien Securitization Bridge Revolving Credit Facility; provided, that
  if an Applebee’s Securitization is consummated pursuant to which securities
  are issued in a principal amount equal to or greater than * (which for the
  avoidance of doubt, includes the amount of any variable funding note
  regardless of whether such note is funded), the commitments under the First
  Lien Securitization Bridge Revolving Credit Facility shall terminate.

  
	
   

  	
   

  	
   

  
	
  Letters of Credit:

  	
   

  	
  $50,000,000 of the First
  Lien Securitization Bridge Revolving Credit Facility will be available for
  letters of credit, on customary terms and conditions to be set forth in the
  First Lien Securitization Bridge Documentation.

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  Each letter
  of credit shall expire not later than the third day prior to the maturity
  date of the First Lien Securitization Bridge Revolving Credit Facility; provided
  that, subject to the terms of the First Lien Securitization Bridge
  Documentation, a letter of credit may provide that it shall automatically
  renew for additional periods.

  
	
   

  	
   

  	
   

  
	
  Swing Line Facility:

  	
   

  	
  A portion of the First
  Lien Securitization Bridge Revolving Credit Facility in an amount to be
  determined will be available for swingline loans on same day notice and on
  terms and conditions to be set forth in the First Lien Securitization Bridge
  Documentation.

  
	
   

  	
   

  	
   

  
	
  Amortization:

  	
   

  	
  First Lien Securitization
  Bridge Term Loan Facility: The First Lien
  Securitization Bridge Term Loan Facility will amortize in equal quarterly
  installments in an aggregate annual amount equal to 1.0% of the aggregate
  principal amount of the First Lien Securitization Bridge Term Loans as of the
  Closing Date, with the balance thereof due at maturity.

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  First Lien
  Securitization Bridge Revolving Credit Facility:
  None.

  

 

__________________

*  This information has been
omitted based on a request for confidential treatment. The omitted portions
have been separately filed with the Securities and Exchange Commission.

 

I-4

 

	
  Interest on First Lien
  Securitization

  	
   

  	
   

  
	
  Bridge Term Loans and Securitization

  	
   

  	
   

  
	
  Bridge Revolving Credit
  Loans:

  	
   

  	
  At the Borrower’s option,
  First Lien Securitization Bridge Term Loans and Securitization Bridge
  Revolving Credit Loans will bear interest based on the Base Rate or LIBOR; provided
  that until the date that is 30 days following the Closing Date, the First
  Lien Securitization Bridge Loans shall be made and maintained as Base Rate
  Loans or LIBOR Loans having an interest period of one month, as selected by
  the Borrower, as described below:

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  A. Base
  Rate Option

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  Interest
  will be at the Base Rate plus the applicable Interest Margin (as defined
  below), calculated on the basis of the actual number of days elapsed in a
  year of 365/66 days and payable quarterly in arrears. The Base Rate is
  defined as the higher of (i) the Federal Funds Rate, as published by the
  Federal Reserve Bank of New York, plus 1/2 of 1% and (ii) the prime
  commercial lending rate as set forth on Reuters’ Telerate Page 5. First Lien
  Securitization Bridge Loans bearing interest based on the Base Rate shall be
  referred to herein as “Base Rate Loans.”

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  Base Rate
  borrowings will require one business day’s prior notice and will be in
  minimum amounts to be agreed upon.

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  B. LIBOR
  Option

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  Interest
  will be determined for periods (“Interest Periods”) of one, two, three
  or six months (as selected by the Borrower) and will be at an annual rate
  equal to the London Interbank Offered Rate (“LIBOR”) for the
  corresponding deposits of U.S. dollars, plus the applicable Interest Margin.
  LIBOR will be determined by the Administrative Agent at the start of each
  Interest Period and will be fixed through such period. Interest will be paid
  at the end of each Interest Period or, in the case of Interest Periods longer
  than three months, quarterly, and will be calculated on the basis of the
  actual number of days elapsed in a year of 360 days. LIBOR will be adjusted
  for maximum statutory reserve requirements (if any). First Lien
  Securitization Bridge Loans bearing interest based on LIBOR shall be referred
  to herein as “LIBOR Loans.”

  

 

 

I-5

 

	
   

  	
   

  	
  LIBOR
  borrowings will require three business days’ prior notice and will be in
  minimum amounts to be agreed upon.

  
	
   

  	
   

  	
   

  
	
  Default Interest:

  	
   

  	
  Upon the occurrence and
  during the continuance of a payment default, interest will accrue on any
  overdue amount of a loan or other overdue amount payable under the First Lien
  Securitization Bridge Facilities at a rate of 2% per annum in excess of the
  rate (including the applicable Interest Margin (as defined below)) otherwise
  applicable to such loan or other amount and will be payable on demand.

  
	
   

  	
   

  	
   

  
	
  Interest Margins:

  	
   

  	
  The interest margins
  applicable to each of the First Lien Securitization Bridge Term Loans and the
  Securitization Bridge Revolving Credit Loans will be the percentages set
  forth in the following table *

  

 

__________________

*  This information has been
omitted based on a request for confidential treatment. The omitted portions
have been separately filed with the Securities and Exchange Commission.

 

I-6

 

 

	
   

  	
   

  	
   

  
	
  *

  	
   

  	
   

  
	
   

  	
   

  	
   

  

 

__________________

*  This information has been
omitted based on a request for confidential treatment. The omitted portions
have been separately filed with the Securities and Exchange Commission.

 

I-7

 

	
   

  	
   

  	
  *

  

 

__________________

*  This information has been
omitted based on a request for confidential treatment. The omitted portions
have been separately filed with the Securities and Exchange Commission.

 

I-8

 

	
   

  	
   

  	
  *

  
	
   

  	
   

  	
   

  
	
  Revolving Credit

  	
   

  	
   

  
	
  Commitment Fees:

  	
   

  	
  A Revolving Credit Commitment Fee shall accrue on
  the unused amounts of the commitments under the First Lien Securitization
  Bridge Revolving Credit Facility at a rate equal to 0.50% per annum. Accrued
  Revolving Credit Commitment Fees will be payable quarterly in arrears
  (calculated on a 360-day basis) for the account of the First Lien
  Securitization Bridge Revolving Credit Lenders from the Closing Date.

  
	
   

  	
   

  	
   

  
	
  Letter of Credit Fees:

  	
   

  	
  The Borrower will pay (i) the Letter of Credit
  Issuing Entity a fronting fee in an amount to be agreed on the face amount of
  each letter of credit issued by such Letter of Credit Issuing Entity and
  (ii) letter of credit participation fees to the First Lien
  Securitization Bridge Revolving Credit Lenders in an amount equal to the
  Interest Margin for LIBOR Loans under the First Lien Securitization Bridge
  Revolving Credit Facility, in each case, on the undrawn amount of all such
  outstanding letters of credit. In addition, the Borrower will pay the Letter
  of Credit Issuing Entity customary and market rate issuances fees, which may
  not be rebated.

  

 

__________________

*  This information has been
omitted based on a request for confidential treatment. The omitted portions
have been separately filed with the Securities and Exchange Commission.

 

I-9

 

	
  Mandatory Prepayments:

  	
   

  	
  An amount equal to
  (a) 100% of the net proceeds (including insurance and condemnation
  proceeds) received from the sale or other disposition of all or any part of
  the assets (other than sales of assets in the ordinary course of business to
  be agreed) of the Borrower or any of its subsidiaries after the Closing Date
  other than in the ordinary course and other than amounts reinvested within
  6 months of the sale or other disposition and subject to other
  exceptions to be agreed and otherwise consistent with recent credit
  documentation governing securitization bridge facilities of this type, provided,
  that the net proceeds of any sale-leaseback transaction shall be applied as a
  mandatory prepayment without any such reinvestment option, (b) 100% of
  the gross proceeds received by the Borrower or any of its affiliates in
  connection with the closing of an Applebee’s Securitization, (c) 100% of
  the gross proceeds received by the Borrower or any of its affiliates in
  connection with the sale of the Additional IHOP Securitization Securities,
  (d) 100% of the net cash proceeds received by the Borrower or any of its
  subsidiaries from any other Securitization or the issuance of other debt
  (other than certain debt permitted to be incurred or assumed under the First
  Lien Securitization Bridge Documentation) or the issuance of any equity after
  the Closing Date (other than exceptions to be agreed), (e) 100% of the gross
  proceeds received by the Borrower or any of its subsidiaries from the unwind
  of the interest rate derivative described in item 5 of Annex III or any replacement
  thereof and (f) beginning with fiscal year 2008, 50% of excess cash flow
  of the Borrower and its subsidiaries (to be defined in a mutually
  satisfactory manner); provided, that any voluntary prepayments of
  loans under the Securitization Bridge Facilities (including Securitization
  Bridge Revolving Credit Loans to the extent the aggregate Securitization
  Bridge Revolving Credit Commitments are permanently reduced (ratably among
  the Securitization Bridge Revolving Credit Lenders) by the amount of such prepayments),
  other than prepayments funded with the proceeds of indebtedness, asset sales
  or other financing transactions, shall be deducted from excess cash flow for
  purposes of calculating amounts available for the excess cash flow mandatory
  prepayment.

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  There will
  be no prepayment penalties (except LIBOR breakage costs) for mandatory
  prepayments.

  

 

I-10

 

	
  Optional
  Prepayments:

  	
   

  	
  Permitted in whole or in part and, in the case of the First Lien
  Securitization Bridge Term Loans, may not be reborrowed, with one business
  day’s prior notice in the case of Base Rate Loans and three business day’s
  prior notice in the case of LIBOR Loans, but without premium or penalty
  (except LIBOR breakage costs in the case of a prepayment other than on the
  last day of the relevant interest period) and including accrued and unpaid
  interest, subject to limitations as to minimum amounts of prepayments to be
  agreed. There will be no prepayment penalties (except LIBOR breakage costs)
  for optional prepayments.

  
	
   

  	
   

  	
   

  
	
  Application of Prepayments:

  	
   

  	
  All mandatory prepayments will be applied, first, to the
  prepayment of the First Lien Securitization Bridge Term Loans, second,
  to the repayment of the First Lien Securitization Bridge Revolving Credit
  Facility (but with no permanent reduction in the commitments thereof) and third,
  to the prepayment of the Second Lien Securitization Bridge Term Loans; provided,
  that a mandatory prepayment described in clause (b) of “Mandatory
  Prepayments” above in connection with a release of the Collateral Agent’s
  lien on the assets of the Acquired Business (as described in “Release of
  Acquired Business Collateral” below) will be applied, first, to the
  prepayment of the First Lien Securitization Bridge Term Loans, second,
  to the repayment of the First Lien Securitization Bridge Revolving Credit
  Facility (with a corresponding permanent reduction in the commitments
  thereof), and third, to the prepayment of the Second Lien
  Securitization Bridge Term Loans. Optional
  prepayments may be applied to the First Lien Securitization Bridge Term Loan
  or the First Lien Securitization Bridge Revolving Credit Facility as directed
  by the Borrower. No optional
  or mandatory prepayments may be applied to the Second Lien Securitization
  Bridge Term Loans until all extensions of credit under the First Lien
  Securitization Bridge Facilities shall have been paid in full and all
  commitments thereunder shall have been terminated. Each prepayment of the
  First Lien Securitization Bridge Term Loans may not be reborrowed.
  Prepayments of Securitization Bridge Revolving Credit Loans may be
  reborrowed.

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  Each
  mandatory and optional prepayment of the First Lien Securitization Bridge
  Term Loans will be applied to the remaining amortization payments of the
  First Lien

  

 

I-11

 

	
   

  	
   

  	
  Securitization
  Bridge Term Loan Facility in the manner directed by the Borrower.

  
	
   

  	
   

  	
   

  
	
  Guarantees:

  	
   

  	
  The obligations of the
  Borrower under the First Lien Securitization Bridge Term Loan Facility and
  the First Lien Securitization Bridge Revolving Credit Facility and any
  exposure under hedging agreements and, at the Borrower’s option, cash
  management arrangements, entered into with a person that was, at the time of
  such entry, a Securitization Bridge Lender (or an affiliate thereof) under
  the First Lien Securitization Bridge Term Loan Facility or the First Lien
  Securitization Bridge Revolving Credit Facility (collectively, the “Obligations”)
  will be fully and unconditionally guaranteed on a joint and several basis by
  all existing and future direct and indirect domestic subsidiaries of the
  Borrower, other than any subsidiaries that are or are intended to become
  bankruptcy remote securitization entities (and such entities’ bankruptcy remote
  subsidiaries) under the Securitization or the IHOP Securitization (the “Guarantors”,
  and, together with the Borrower, the “Loan Parties”).

  
	
   

  	
   

  	
   

  
	
  Security:

  	
   

  	
  As security for the
  Obligations of each Loan Party, each Loan Party shall grant to the Collateral
  Agent, for the benefit of the First Lien Securitization Bridge Lenders and
  each other holder of the Obligations, valid and perfected first priority
  liens and security interests in all of the following (collectively, the “Collateral”),
  subject to the terms of the Conditions Annex:

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  (a) a
  first-priority pledge of (i) all notes owned by the Loan Parties,
  including, without limitation, all intercompany notes owing to the Loan
  Parties (and any collateral pledged as security therefor) and (ii) all
  capital stock held by the Loan Parties in their respective subsidiaries
  (whether existing or subsequently acquired or organized, or domestic or
  foreign); provided, that in the case of any first-tier foreign
  subsidiary, not more than 66% of the voting stock of such foreign subsidiary
  shall be pledged by the applicable Loan Party as security for the
  Obligations; and

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  (b) perfected
  first-priority security interests in, and mortgages on, all owned, leased or
  licensed material tangible and intangible assets (including, without
  limitation, accounts receivable, inventory, equipment, vehicles, general
  intangibles, insurance policies, investment property, intellectual property,
  cash and deposit accounts, the interest reserve accounts (which

  

 

I-12

 

	
   

  	
  shall be at LBCB pursuant to documentation reasonably satisfactory to
  the Collateral Agent) and funded with an estimated three months’ aggregate
  interest under the Applebee’s Securitization and IHOP Securitization) and
  owned real property) and proceeds of the foregoing of the Loan Parties,
  wherever located, now or hereafter owned; provided, however, that the Loan
  Parties shall not be required to perfect such security interests in
  (x) vehicles, (y) deposit accounts until 90 days following the
  Closing Date or, if an Event of Default has occurred and is continuing, upon
  the request of the Collateral Agent, and (z) owned real property until
  180 days following the Closing Date or, if an Event of Default has occurred
  and is continuing, upon the reasonable request of the Collateral Agent. The
  foregoing notwithstanding, the Collateral shall not include (i) assets
  as to which the Administrative Agent shall reasonably determine that the
  costs of obtaining such a security interest are excessive in relation to the
  value of the security to be afforded thereby, (ii) assets to the extent
  that the granting of such security interest would violate any applicable law
  or the enforceable anti-assignment provisions of any contract,
  (iii) leasehold interests in real property, (iv) off-the-shelf
  software licenses and (v) other exceptions to be agreed.

  
	
   

  	
   

  
	
   

  	
  The obligations under the
  Second Lien Securitization Bridge Loan Facility will be secured by a
  second-priority security interest in the Collateral. The priority of the
  security interests and the related creditor rights among the First Lien
  Securitization Bridge Facilities and the Second Lien Securitization Bridge
  Loan Facility will be set forth in an intercreditor agreement (“Intercreditor
  Agreement”) to be agreed upon.

  
	
   

  	
   

  
	
   

  	
  The Borrower
  may designate certain interest hedging and cash management obligations
  in respect of the Securitization Bridge Facilities or the corresponding
  Securitization securities on terms and with counterparties acceptable to the
  Administrative Agent to share in the first-priority security interest in the
  Collateral.

  
	
   

  	
   

  
	
  Conditions
  to Initial Borrowings:

  	
  Conditions
  precedent to initial borrowings under the First Lien Securitization Bridge
  Facilities will be limited to those described or referred to under the heading
  “Conditions” in the Commitment Letter, and those conditions set forth in
  Annex III to the Commitment Letter and the following: (1) the
  accuracy of the Specified Representations and (2) delivery of a duly

  

 

I-13

 

	
   

  	
   

  	
  executed
  notice of borrowing under the First Lien Securitization Bridge Facilities.

  
	
   

  	
   

  	
   

  
	
  Conditions
  to Each Borrowing

  (other than the Initial Borrowings):

  	
   

  	
  

  Conditions precedent to each borrowing or issuance (other than the initial
  borrowings) under the First Lien Securitization Bridge Facilities will be
  limited to the following: (1) the absence of any continuing default or
  event of default, (2) the accuracy of representations and warranties in
  all material respects and (3) delivery of a duly executed notice of
  borrowing.

  
	
   

  	
   

  	
   

  
	
  Representations
  and Warranties:

  	
   

  	
  Representations
  and warranties will be subject to materiality thresholds and exceptions to be
  agreed, apply to the Borrower and its subsidiaries (including, without
  limitation, the Acquired Business) and will be limited to the following:
  financial statements (including pro forma financial statements); absence of
  undisclosed liabilities; no material adverse change; corporate existence;
  compliance with law; corporate power and authority; enforceability of the
  First Lien Securitization Bridge Documentation; no conflict with law or
  contractual obligations; no material litigation; no default; ownership of
  property; liens; intellectual property; real property; taxes; permits;
  governmental and other approvals; subsidiaries; governmental regulations
  (including Federal Reserve regulations; ERISA; the Investment Company Act and
  the Patriot Act); environmental matters; solvency; labor matters; employment
  and management agreements; accuracy of disclosure; insurance; creation and
  perfection of security interests; capitalization; use of proceeds; delivery
  of documents; and fees and expenses.

  
	
   

  	
   

  	
   

  
	
  Affirmative
  Covenants:

  	
   

  	
  Affirmative
  covenants will be subject to materiality thresholds and exceptions to be agreed,
  apply to the Borrower and its subsidiaries (including, without limitation,
  the Acquired Business) and will be limited to the following: delivery of
  financial statements, management reports, accountants’ letters, business
  plan, officers’ certificates and other customary information; payment of
  taxes and other obligations; continuation of business and maintenance of
  existence and material rights and privileges; compliance with material laws
  and regulations (including, without limitation, environmental, ERISA and tax
  laws and regulations); maintenance of property and insurance; maintenance of
  books and records; inspection rights; notices of defaults, litigation and
  other material events; environmental

  

 

I-14

 

	
   

  	
   

  	
  matters;
  use of proceeds; fiscal year; material contracts; interest rate protection;
  transfer of assets to special purpose entity; and further assurances with
  respect to guarantees, security interests and related matters.

  
	
   

  	
   

  	
   

  
	
  Negative
  Covenants:

  	
   

  	
  Negative
  covenants will be subject to materiality thresholds and exceptions to be
  agreed, apply to the Borrower and its subsidiaries (including, without
  limitation, the Acquired Business) and will be limited to the following:
  limitation on asset sales and changes of business; limitation on mergers,
  liquidations, dissolutions and other fundamental changes; prohibition on cash
  dividends, stock repurchases and redemptions (including, without limitation,
  with respect to any preferred stock) (other than *); and provided, further,
  that, no payment may be made under clause (i), (ii) or
  (iii) above unless both immediately before and after giving effect to
  such payment, no Default or Event of Default exists); limitation on
  indebtedness (including preferred stock of subsidiaries and guarantees and
  other contingent obligations); limitation on investments; limitation on liens
  and negative pledge with respect to unperfected collateral; limitation on
  transactions with affiliates;

  

 

__________________

*  This information has been omitted based on a
request for confidential treatment. The omitted portions have been separately
filed with the Securities and Exchange Commission.

 

I-15

 

	
   

  	
   

  	
  limitation
  on hedging agreements; prohibition on prepayments of subordinated
  indebtedness; limitation on prepayments under the Second Lien Securitization
  Bridge Facility; no modification, amendment or waiver of the terms of
  constituent documents or the documents governing the IHOP Securitization in any
  manner materially adverse to the First Lien Securitization Bridge Lenders
  without the consent of the Requisite First Lien Securitization Bridge Lenders
  (as defined below); limitation on sale-leaseback transactions; limitation on
  restrictions on distributions from subsidiaries and granting of negative
  pledge clauses; limitation on change to line of business; limitation on
  changes in accounting treatment or reporting practices (with exceptions
  relating to accounting changes necessitated by, or desirable in light of, the
  Acquisition); limitation on changes in fiscal year; limitation on use of
  proceeds in contravention of margin regulations; and limitation on capital
  expenditures per fiscal year (to be set at * cushion over forecast).

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  “Loan
  Year” means an annual period commencing on an anniversary of the Closing
  Date and ending on the day immediately preceding the next anniversary of the
  Closing Date.

  
	
   

  	
   

  	
   

  
	
  *

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  Events
  of Default:

  	
   

  	
  Events
  of Default will apply to the Borrower and its subsidiaries (including,
  without limitation, the Acquired Business) and will be limited to:
  nonpayment, inaccuracy of representations and warranties, breach of
  covenants, cross defaults, loss of material lien on collateral, actual or
  asserted invalidity of any guarantee or security document provisions,
  bankruptcy and insolvency events, dissolution, ERISA events, material
  environmental events, material judgments and change of control (to be
  defined), in certain cases to be agreed

  

 

__________________

*  This information has been omitted based on a
request for confidential treatment. The omitted portions have been separately
filed with the Securities and Exchange Commission.

 

I-16

 

	
   

  	
   

  	
  subject
  to grace periods and materiality thresholds or exceptions to be agreed.

  
	
   

  	
   

  	
   

  
	
  Assignments
  and Participations:

  	
   

  	
  Each
  First Lien Securitization Bridge Lender may assign all or a portion of
  its loans and commitments under one or more of the First Lien Securitization
  Bridge Facilities. Assignments will require the consent of the Administrative
  Agent, the Letter of Credit Issuing Entity (with respect to Securitization
  Bridge Revolving Credit Loans and Securitization Bridge Revolving Credit
  Commitments), the Swing Line Lender (with respect to Securitization Bridge
  Revolving Credit Loans and Securitization Bridge Revolving Credit
  Commitments) and the Borrower, which consents shall not be unreasonably
  withheld; provided  that no
  consent of the Borrower shall be required during the first twelve months following
  the Closing Date or during the occurrence and continuance of a payment or
  bankruptcy Event of Default, except for assignments to certain financial
  institutions identified in writing by the Borrower to the Sole Arranger prior
  to the commencement of syndication of the Securitization Bridge Facilities;
  and provided  further, that no consents (except from the Letter
  of Credit Issuing Entity and the Swing Line Lender (with respect to
  Securitization Bridge Revolving Credit Loans and Securitization Bridge Revolving
  Credit Commitments)) shall be required for an assignment to an existing First
  Lien Securitization Bridge Lender or an affiliate of an existing First Lien
  Securitization Bridge Lender. Each assignment (except to other First Lien
  Securitization Bridge Lenders or their affiliates) will be in a minimum
  amount of (i) $5,000,000 in respect of Securitization Bridge Revolving
  Credit Loans and Securitization Bridge Revolving Credit Commitments and
  (ii) $1,000,000 in respect of First Lien Securitization Bridge Term
  Loans. In addition, each First Lien Securitization Bridge Lender
  may sell participations in all or a portion of its loans and commitments
  under one or more of the First Lien Securitization Bridge Facilities; provided
  that no purchaser of a participation shall have (a) the right to
  exercise or to cause the selling First Lien Securitization Bridge Lender to
  exercise voting rights in respect of the First Lien Securitization Bridge
  Facilities (except as to certain customary issues) or (b) the right to
  yield protection in an amount exceeding that available to the relevant First
  Lien Securitization Bridge Lender.

  

 

I-17

 

	
  Release
  of Acquired

  Business/Collateral:

  	
   

  	
  

  Concurrently with the consummation of the Applebee’s Securitization, provided
  that (i) the aggregate principal amount of securities issued thereunder
  is not less than * (which
  for the avoidance of doubt, includes the amount of any variable funding note
  regardless of whether such note is funded) and the gross proceeds
  therefrom are applied directly to repay the Securitization Bridge Facilities
  in accordance with “Application of Prepayments” above and (ii) the
  commitments under the First Lien Securitization Bridge Revolving Credit
  Facility have been terminated, the Collateral Agent shall be authorized to
  release its lien on the assets of the Acquired Business that will be
  transferred into the Applebee’s Securitization in connection therewith.

  
	
   

  	
   

  	
   

  
	
  Expenses
  and Indemnification:

  	
   

  	
  All
  reasonable out-of-pocket expenses (including but not limited to reasonable
  legal fees and expenses of counsel and expenses incurred in connection with
  due diligence and travel, courier, reproduction, printing and delivery
  expenses, but excluding any such legal fees and expenses of Paul, Weiss,
  Rifkind, Wharton & Garrison LLP in connection with its due diligence
  investigation of the assets and business of the Borrower and its existing
  subsidiaries (which, for the avoidance of doubt, excludes the Acquired
  Business)) of the Sole Arranger, the Administrative Agent and the Collateral
  Agent associated with the syndication of the First Lien Securitization Bridge
  Facilities and with the preparation, execution and delivery, administration,
  amendment, waiver or modification (including proposed amendments, waivers or
  modifications) of the documentation contemplated hereby are to be paid by the
  Borrower on demand whether or not the Closing Date shall occur. In addition,
  all out-of-pocket expenses (including but not limited to legal fees and expenses
  of counsel) of the Securitization Bridge Lenders, the Administrative Agent
  and the Collateral Agent for workout proceedings, enforcement costs and
  documentary taxes associated with the First Lien Securitization Bridge
  Facilities are to be paid by the Borrower on demand.

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  The Borrower will
  indemnify the First Lien Securitization Bridge Lenders, the Sole Arranger,
  the Administrative Agent and the Collateral Agent and their respective
  affiliates, and hold them harmless from and against all documented reasonable
  out-of-pocket costs,

  

 

__________________

*  This information has been omitted based on a
request for confidential treatment. The omitted portions have been separately
filed with the Securities and Exchange Commission.

 

I-18

 

	
   

  	
   

  	
  expenses (including but
  not limited to documented reasonable legal fees and expenses of not more than
  one counsel plus, if necessary, one local counsel per jurisdiction) and
  liabilities arising out of or relating to the transactions contemplated
  hereby and any actual or proposed use of the proceeds of any loans made under
  the First Lien Securitization Bridge Facilities; provided, however,
  that no such person will be indemnified for costs, expenses or liabilities
  (i) to the extent determined by a court of competent jurisdiction to
  have been incurred by reason of the gross negligence, willful misconduct or
  bad faith of, or material breach of the Securitization Bridge Documentation
  by, such person or (ii) arising out of or in connection with any claim,
  litigation, investigation or proceeding that does not involve an act or
  omission of the Borrower or any of its affiliates and that is brought by an
  indemnified person against any other indemnified person.

  
	
   

  	
   

  	
   

  
	
  Yield
  Protection, Taxes

  and Other Deductions:

  	
   

  	
  

  The First Lien Securitization Bridge Documentation will contain yield
  protection provisions, customary for facilities of this nature, protecting
  the First Lien Securitization Bridge Lenders in the event of breakage losses,
  reserve and capital adequacy requirements.

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  All payments are to be
  free and clear of any present or future taxes, withholdings or other
  deductions whatsoever (other than income and franchise taxes in the
  jurisdiction of the First Lien Securitization Bridge Lender’s applicable
  lending office). The First Lien Securitization Bridge Lenders will use
  reasonable efforts to minimize to the extent possible any applicable taxes
  and the Borrower will indemnify (subject to customary exceptions) the
  relevant First Lien Securitization Bridge Lenders and the Administrative
  Agent for such taxes paid by such First Lien Securitization Bridge Lenders or
  the Administrative Agent.

  
	
   

  	
   

  	
   

  
	
  Requisite First Lien
  Securitization

  Bridge Lenders:

  	
   

  	
  First Lien Securitization
  Bridge Lenders holding at least a majority of total loans and commitments
  under the First Lien Securitization Bridge Facilities (the “Requisite
  First Lien Securitization Bridge Lenders”), with certain amendments
  requiring the consent of First Lien Securitization Bridge Lenders holding a
  greater percentage (or each First Lien Securitization Bridge Lender affected)
  of the total loans and commitments under the First Lien Securitization

  

 

I-19

 

	
   

  	
   

  	
  Bridge Facilities (subject
  to a customary “yank-a-bank” provision).

  
	
   

  	
   

  	
   

  
	
  Certain
  Securitization

  Related Provisions:

  	
   

  	
  

  If (1) the Applebee’s Securitization will result in the repayment of *
  (less any undrawn commitment amounts under the Securitization Bridge
  Facilities at the time the Applebee’s Securitization closes) in aggregate
  principal amount of the Securitization Bridge Facilities or (2) 100% of
  the Securitization Bridge Lenders shall have otherwise consented to the
  closing of the Applebee’s Securitization, then and only then each First Lien
  Securitization Bridge Lender covenants, for itself and for the express
  benefit of the secured parties under the Applebee’s Securitization:

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  (i) that it shall
  have no recourse whatsoever to any of the collateral underlying the
  Applebee’s Securitization;

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  (ii) that it will not
  (and hereby waives any right to) contest or support any other person in
  contesting, in any proceeding (including any insolvency or liquidation
  proceeding), (x) the priority, validity, perfection or enforceability of the
  first priority perfected security interest held by or on behalf of the
  secured parties under the Applebee’s Securitization, as the case may be,
  and/or (y) the validity or enforceability of the provisions of any of the
  transaction documents underlying the Applebee’s Securitization; and

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  (iii) so long as
  any amounts are outstanding under the Applebee’s Securitization, and for a
  period of one year plus one day (or, if longer, the applicable preference
  period then in effect) after payment in full of all amounts payable in
  connection with the transaction documents underlying the Applebee’s
  Securitization, including but not limited to the notes issued under the
  Applebee’s Securitization, such First Lien Securitization Bridge Lenders,
  agents and letter of credit issuers shall not institute against any of the
  subsidiaries of the Borrower that are bankruptcy remote securitization
  entities (or are intended to be bankruptcy remote securitization entities)
  under the Applebee’s Securitization or their bankruptcy remote subsidiaries
  (such actual or intended bankruptcy remote entities and their bankruptcy
  remote subsidiaries, the “Applebee’s Securitization Entities”) , or
  join or assist any other person in instituting against any of the Applebee’s
  Securitization Entities, any bankruptcy, reorganization, arrangement,
  insolvency or liquidation

  

 

__________________

*  This information has been omitted based on a
request for confidential treatment. The omitted portions have been separately
filed with the Securities and Exchange Commission.

 

I-20

 

	
   

  	
   

  	
  proceedings, or other
  proceedings under any applicable federal or state bankruptcy or similar law.

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  Each First Lien
  Securitization Bridge Lender covenants, for itself and for the express
  benefit of the secured parties under the IHOP Securitization (which for all
  purposes of this provision, includes the Additional IHOP Securitization
  Securities):

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  (i) that it shall
  have no recourse whatsoever to any of the collateral underlying the IHOP
  Securitization;

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  (ii) that it will not
  (and hereby waives any right to) contest or support any other person in
  contesting, in any proceeding (including any insolvency or liquidation
  proceeding), (x) the priority, validity, perfection or enforceability of the
  first priority perfected security interest held by or on behalf of the
  secured parties under the IHOP Securitization, as the case may be,
  and/or (y) the validity or enforceability of the provisions of any of the
  transaction documents underlying the IHOP Securitization; and

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  (iii) so long as
  any amounts are outstanding under the IHOP Securitization, and for a period
  of one year plus one day (or, if longer, the applicable preference period
  then in effect) after payment in full of all amounts payable in connection
  with the transaction documents underlying the IHOP Securitization, including
  but not limited to the notes issued under the IHOP Securitization, such First
  Lien Securitization Bridge Lenders, agents and letter of credit issuers shall
  not institute against any of the subsidiaries of the Borrower that are
  bankruptcy remote securitization entities (or are intended to be bankruptcy
  remote securitization entities) under the IHOP Securitization or their
  bankruptcy remote subsidiaries (such actual or intended bankruptcy remote
  entities and their bankruptcy remote subsidiaries, the “IHOP
  Securitization Entities”) , or join or assist any other person in
  instituting against any of the IHOP Securitization Entities, any bankruptcy,
  reorganization, arrangement, insolvency or liquidation proceedings, or other
  proceedings under any applicable federal or state bankruptcy or similar law.

  
	
   

  	
   

  	
   

  
	
  Governing
  Law and Forum:

  	
   

  	
  The
  laws of the State of New York. Each party to the First Lien Securitization
  Bridge Documentation will waive the right to trial by jury and will consent
  to jurisdiction of the state and federal courts located in The City of
  New York.

  

 

I-21

 

	
  Counsel to
  the Sole Arranger

  and the Administrative Agent:

  	
   

  	
  

  Paul, Weiss, Rifkind, Wharton & Garrison LLP.

  

 

I-22

 

ANNEX I

 

SUMMARY OF TERMS OF SECOND LIEN SECURITIZATION BRIDGE LOAN
FACILITY

 

	
  Borrower: 

  	
   

  	
  IHOP Corp. 

  
	
   

  	
   

  	
   

  
	
  Exclusive Structuring
  Advisor:

  	
   

  	
  Lehman Brothers Inc. (“Lehman
  Brothers”).

  
	
   

  	
   

  	
   

  
	
  Sole Arranger and Sole

  Bookrunner:

  	
   

  	
  Lehman Brothers.

  
	
   

  	
   

  	
   

  
	
  Second Lien Securitization

  Bridge Lenders:

  	
   

  	
  The Initial Securitization
  Bridge Lender or a syndicate of banks, financial institutions and other
  entities arranged by the Sole Arranger (collectively, the “Second Lien
  Securitization Bridge Lenders”); provided that any such
  syndication shall comply with the terms and conditions set forth in the
  Commitment Letter.

  
	
   

  	
   

  	
   

  
	
  Administrative Agent and

  Collateral Agent:

  	
   

  	
  Lehman Brothers Commercial
  Bank (“LBCB”) or Lehman Commercial Paper Inc. (“LCPI”).

  
	
   

  	
   

  	
   

  
	
  Syndication Agent:

  	
   

  	
  LBCB, LCPI or one of their
  affiliates.

  
	
   

  	
   

  	
   

  
	
  Type and Amount of

  Facilities:

  	
   

  	
  Second Lien Securitization
  Bridge Loan Facility:

   

  A one-year term
  securitization bridge term loan facility to be made available to the Borrower
  in U.S. dollars in the manner provided herein (the “Second Lien
  Securitization Bridge Loan Facility”; and the loans made under the Second
  Lien Securitization Bridge Facility, the “Second Lien Securitization
  Bridge Loans”) in an aggregate principal amount of up to $189,000,000.

  
	
   

  	
   

  	
   

  
	
  Purpose:

  	
   

  	
  Proceeds of the Second
  Lien Securitization Bridge Loan Facility will be used on the Closing Date (as
  defined below) to finance a portion of the Acquisition, to effect the
  Refinancing and to pay fees and expenses in connection therewith.

  
	
   

  	
   

  	
   

  
	
  Closing Date:

  	
   

  	
  Same as the First Lien
  Securitization Bridge Facilities.

  

 

II-1

 

	
  Definitive Documentation:

  	
   

  	
  The terms of the
  definitive documentation governing the Second Lien Securitization Bridge Loan
  Facility (the “Second Lien Securitization Bridge Documentation”) shall
  be consistent with the terms and conditions of the Commitment Letter.

  
	
   

  	
   

  	
   

  
	
  Maturity Dates:

  	
   

  	
  Second Lien Securitization
  Bridge Loan Facility: One year from the Closing Date.

   

  If any Second Lien
  Securitization Bridge Loans (the “Second Lien Initial Loans”) have not
  been previously paid in full the date that is one year after the Closing Date
  (the “Conversion Date”), subject to the conditions outlined below
  under “Condition to Conversion of Second Lien Initial Loans,” such Second
  Lien Initial Loans shall be converted into a second lien term loan (each, a “Second
  Lien Term Loan” and, together with the Senior Term Loans, the “Term
  Loans”) maturing on the fourth anniversary of the Conversion Date (the “Second
  Lien Final Maturity Date”). Other than the maturity date, all terms and
  conditions set forth herein applicable to the Second Lien Securitization
  Bridge Loan Facility shall apply to the Second Lien Term Loan.

  
	
   

  	
   

  	
   

  
	
  Conditions to Conversion
  of

  Second Lien Initial Loans:

  	
   

  	
  On the Conversion Date,
  unless a payment or bankruptcy default has occurred and is continuing under
  the Second Lien Initial Loans, the Second Lien Initial Loans shall be
  converted into Second Lien Term Loans upon payment of the Conversion Fee (as
  defined in the Fee Letter).

  
	
   

  	
   

  	
   

  
	
  Prepayment Premium

  on Converted Loans:

  	
   

  	
  Any optional prepayment of
  the Second Lien Term Loans prior to the first anniversary of the Conversion
  Date shall be accompanied by a prepayment premium equal to 2% of the
  aggregate principal amount prepaid, and any optional prepayment occurring on
  or after the first anniversary and before the second anniversary of the
  Conversion Date shall be accompanied by a prepayment premium equal to 1% of
  the aggregate principal amount prepaid.

  
	
   

  	
   

  	
   

  
	
  Availability:

  	
   

  	
  A single drawing may be
  made on the Closing Date of up to the full amount of the Second Lien
  Securitization Bridge Facility; provided, that if the Applebee’s
  Securitization is consummated on the Closing Date, the amount of the Second
  Lien Securitization Bridge Facility shall be reduced by the greater of
  (x) * and (y) the extent to which the aggregate principal amount of
  securities issued in the Applebee’s Securitization exceeds * (which for the
  avoidance of doubt, includes the amount of any variable funding note
  regardless of whether such note is funded).

  
	
   

  	
   

  	
   

  
	
  Amortization:

  	
   

  	
  None.

  

 

__________________

*  This information has been omitted based on a
request for confidential treatment. The omitted portions have been separately
filed with the Securities and Exchange Commission.

 

II-2

 

	
  Interest on Second Lien

  Securitization Bridge Loans:

  	
   

  	
  At the Borrower’s option,
  Second Lien Securitization Bridge Term Loans will bear interest based on the
  Base Rate or LIBOR; provided that until the date that is 30 days
  following the Closing Date, the Second Lien Securitization Bridge Loans shall
  be made and maintained as Base Rate Loans or LIBOR Loans having an interest
  period of one month, as selected by the Borrower, as described below:

   

  A. Base Rate Option

   

  Interest will be at the
  Base Rate plus the applicable Interest Margin (as defined below), calculated
  on the basis of the actual number of days elapsed in a year of 365/66 days
  and payable quarterly in arrears. The Base Rate is defined as the higher of
  (i) the Federal Funds Rate, as published by the Federal Reserve Bank of
  New York, plus 1/2 of 1% and (ii) the prime commercial lending rate
  as set forth on Reuters’ Telerate Page 5. Second Lien Securitization Bridge
  Loans bearing interest based on the Base Rate shall be referred to herein as
  “Base Rate Loans.”

   

  Base Rate borrowings will
  require one business day’s prior notice and will be in minimum amounts to be
  agreed upon

   

  B. LIBOR Option

   

  Interest will be
  determined for periods (“Interest Periods”) of one, two, three or six
  months (as selected by the Borrower) and will be at an annual rate equal to
  the London Interbank Offered Rate (“LIBOR”) for the corresponding
  deposits of U.S. dollars, plus the applicable Interest Margin. LIBOR will be
  determined by the Administrative Agent at the start of each Interest Period
  and will be fixed through such period. Interest will be paid at the end of
  each Interest Period or, in the case of Interest Periods longer than three
  months, quarterly, and will be calculated on the basis of the actual number
  of days elapsed in a year of 360 days. LIBOR will be adjusted for maximum
  statutory reserve requirements (if any). Second Lien Securitization Bridge
  Loans bearing interest based on LIBOR shall be referred to herein as “LIBOR
  Loans.”

   

  LIBOR borrowings will
  require three business days’ prior notice and will be in minimum amounts to
  be agreed upon.

  
	
   

  	
   

  	
   

  
	
  Default Interest:

  	
   

  	
  Same as the First Lien
  Securitization Bridge Facilities.

  
	
   

  	
   

  	
   

  
	
  Interest Margins:

  	
   

  	
  The Interest Margins
  applicable to the Second Lien Securitization Bridge Loans will be the
  percentages set forth in the following table *

  

 

__________________

*  This information has been omitted based on a
request for confidential treatment. The omitted portions have been separately
filed with the Securities and Exchange Commission.

 

II-3

 

	
   

  	
   

  	
  *

  

 

 

__________________

*  This information has been omitted based on a
request for confidential treatment. The omitted portions have been separately
filed with the Securities and Exchange Commission.

 

II-4

 

	
   

  	
   

  	
  *

  
	
   

  	
   

  	
   

  
	
  *

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
  Mandatory Prepayments:

  	
   

  	
  Same as the First Lien
  Securitization Bridge Facility, but subject to the Intercreditor Agreement.

  
	
   

  	
   

  	
   

  
	
  Optional Prepayments:

  	
   

  	
  Permitted in whole or in
  part only after the First Lien Securitization Bridge Facilities shall have
  been repaid in full and the commitments thereunder terminated, with one
  business day’s prior notice in the case of Base Rate Loans and three business
  day’s prior notice in the case of LIBOR Loans, but without premium or penalty
  (except LIBOR breakage costs in the case of a prepayment other than on the
  last day of the relevant interest period and except as set forth above under
  the heading “Prepayment Premium on Converted Loans”), and including accrued
  and unpaid interest, subject to limitations as to minimum amounts of
  prepayments to be agreed.

  
	
   

  	
   

  	
   

  
	
  Application of Prepayments:

  	
   

  	
  All mandatory prepayments
  will be applied, first, to the prepayment of the First Lien
  Securitization Bridge Term Loans, second, to the repayment of the
  First Lien Securitization Bridge Revolving Credit Facility (with no permanent
  reduction in the commitments thereof) and third, to the prepayment of
  the Second Lien Securitization Bridge Loans; provided, that a
  mandatory prepayment described in clause (b) of “Mandatory Prepayments” in
  Annex I to the Commitment Letter in connection with a release of the
  Collateral Agent’s lien on the assets of the Acquired Business (as described
  in “Release of Acquired Business Collateral” in Annex I to the Commitment Letter)
  will be applied, first, to the prepayment of the First Lien
  Securitization Bridge Term Loans, second, to the repayment of the
  First Lien Securitization Bridge Revolving Credit Facility (with a
  corresponding permanent reduction in the commitments thereof) and third,
  to the prepayment of the Second Lien Securitization Bridge Term Loans. No
  optional prepayments may be applied to the Second Lien Securitization Bridge
  Term Loans until all extensions of credit under the First Lien Securitization
  Bridge Facilities shall have been paid in full and all commitments thereunder
  shall have been terminated. Prepayments of the Second Lien Securitization
  Bridge Loans may not be reborrowed.

   

  Subject to the foregoing,
  optional and mandatory prepayments shall be applied pursuant to usual and
  customary provisions for applications of prepayments.

  
	
   

  	
   

  	
   

  
	
  Guarantees:

  	
   

  	
  Same as First Lien
  Securitization Bridge Facilities, subject to the Intercreditor Agreement.

  

 

__________________

*  This information has been omitted based on a request
for confidential treatment. The omitted portions have been separately filed
with the Securities and Exchange Commission.

 

II-5

 

	
  Security:

  	
   

  	
  Same as First Lien
  Securitization Bridge Facilities, provided that the Second Lien
  Securitization Bridge Loan Facility will be secured by a second-priority
  security interest in the Collateral.

   

  The priority of the
  security interests and the related creditor rights among the First Lien
  Securitization Bridge Facilities and the Second Lien Securitization Bridge
  Loan Facility will be set forth in the Intercreditor Agreement to be agreed
  upon.

  
	
   

  	
   

  	
   

  
	
  Conditions to Initial

  Borrowings:

  	
   

  	
  Same as the First Lien
  Securitization Bridge Facilities.

  
	
   

  	
   

  	
   

  
	
  Conditions to Each
  Borrowing

  (other than the

  Initial Borrowings):

  	
   

  	
  Same as the First Lien
  Securitization Bridge Facilities.

  
	
   

  	
   

  	
   

  
	
  Representations and

  Warranties:

  	
   

  	
  Same as the First Lien
  Securitization Bridge Facilities.

  
	
   

  	
   

  	
   

  
	
  Affirmative Covenants:

  	
   

  	
  Same as the First Lien
  Securitization Bridge Facilities.

  
	
   

  	
   

  	
   

  
	
  Negative Covenants *:

  	
   

  	
  Same as the First Lien
  Securitization Bridge Facilities, but less restrictive in certain respects to
  be agreed.

  
	
   

  	
   

  	
   

  
	
  Events of Default:

  	
   

  	
  Same as the First Lien
  Securitization Bridge Facilities.

  
	
   

  	
   

  	
   

  
	
  Assignments and

  Participations:

  	
   

  	
  Same as the First Lien
  Securitization Bridge Facilities.

  
	
   

  	
   

  	
   

  
	
  Release of Securitization

  Collateral:

  	
   

  	
  Same as the First Lien
  Securitization Bridge Facilities.

  
	
   

  	
   

  	
   

  
	
  Expenses and

  Indemnification:

  	
   

  	
  Same as the First Lien
  Securitization Bridge Facilities.

  
	
   

  	
   

  	
   

  
	
  Yield Protection, Taxes

  and Other Deductions:

  	
   

  	
  The Second Lien
  Securitization Bridge Documentation will contain yield protection provisions,
  customary for facilities of this nature, protecting the Second Lien
  Securitization Bridge Lenders in the event of breakage losses, reserve and
  capital adequacy requirements.

   

  All payments are to be
  free and clear of any present or future taxes, withholdings or other
  deductions whatsoever (other than income and franchise taxes in the
  jurisdiction of the Second Lien Securitization Bridge Lender’s applicable
  lending office). The Second Lien Securitization Bridge Lenders will use
  reasonable efforts to minimize to the extent possible any applicable taxes
  and the Borrower will indemnify (subject to customary exceptions) the
  relevant Second Lien Securitization Bridge Lenders and the Administrative
  Agent for such taxes paid by such Second Lien Securitization Bridge Lenders
  or the 

  

 

__________________

*  This information has been omitted based on a
request for confidential treatment. The omitted portions have been separately
filed with the Securities and Exchange Commission.

 

II-6

 

	
   

  	
   

  	
  Administrative Agent.

  
	
   

  	
   

  	
   

  
	
  Requisite Second Lien

  Securitization Bridge

  Lenders:

  	
   

  	
  Second Lien Securitization
  Bridge Lenders holding at least a majority of total loans under the Second
  Lien Securitization Bridge Loan Facility (the “Requisite Second Lien
  Securitization Bridge Lenders”), with certain amendments requiring the
  consent of Second Lien Securitization Bridge Lenders holding a greater
  percentage (or each Second Lien Securitization Bridge Lender affected) of the
  total loans under the Second Lien Securitization Bridge Loan Facility
  (subject to a customary “yank-a-bank” provision).

  
	
   

  	
   

  	
   

  
	
  Certain Securitization

  Related Provisions:

  	
   

  	
  Same as the First Lien Securitization Bridge
  Facilities.

  
	
   

  	
   

  	
   

  
	
  Governing Law and Forum:

  	
   

  	
  Same as the First Lien
  Securitization Bridge Facilities.

  
	
   

  	
   

  	
   

  
	
  Counsel to the Sole
  Arranger and the

  Administrative Agent:

  	
   

  	
  Paul, Weiss, Rifkind,
  Wharton & Garrison LLP.

  

 

II-7

ANNEX III

 

CONDITIONS TO CLOSING

 

The commitments of the Initial Securitization Bridge
Lender under the Commitment Letter and the agreement of the Sole Arranger to
perform the services described in the Commitment Letter with respect to each of
the Securitization Bridge Facilities are subject to the conditions described or
referred to under the heading “Conditions” in the Commitment Letter, including the
satisfaction or waiver of each of the conditions precedent set forth below, it
being understood that there shall be no conditions to closing or the initial
funding of the Securitization Bridge Facilities other than those expressly
described or referred to under the heading “Conditions” in the Commitment
Letter, including those set forth below.

 

1.             As
a condition to the availability of the Securitization Bridge Facilities (but
subject to the second paragraph under the heading “Conditions” in the Commitment
Letter), there shall have occurred the negotiation, execution and delivery of
definitive documentation, including guarantees, security documents, customary
opinions, certificates and other closing documentation and deliveries as the
Sole Arranger shall reasonably request with respect to the Securitization
Bridge Facilities, in each case, reflecting and consistent with the terms and
conditions set forth herein and in Annex I and Annex II hereto, as
applicable, and otherwise mutually agreed by the Sole Arranger and the Borrower
(such documentation, together with the Commitment Letter and the Fee Letter,
collectively, the “Securitization Bridge Documentation”).

 

2.             The
Equity Financing shall have been completed. The Acquisition and the other
Transactions shall be consummated concurrently with the initial funding of the
Securitization Bridge Facilities in accordance with the Acquisition Agreement
(and no provision of the Acquisition Agreement shall have been waived or
amended in a manner that is material and adverse to the Sole Arranger or the
Securitization Bridge Lenders unless consented to by the Sole Arranger, which
consent shall not be unreasonably withheld, conditioned or delayed; it being
agreed that (i) any amendment or waiver of Section 2.02, the provisions of the
first two sentences of Section 6.09(a) and Section 6.09(b) of the Acquisition
Agreement would be material and adverse to the Securitization Bridge Lenders,
(ii) the Borrower shall not consent to a Closing Date under Section 2.02 of the
Acquisition Agreement that would occur earlier than the second business day
after the date of completion of the “Bridge Marketing Period” (as defined in
the Acquisition Agreement) without the prior written consent of the Sole
Arranger, such consent not to be unreasonably withheld, conditioned or delayed
and (iii) the Borrower shall consult with the Sole Arranger prior to
determining whether an early commencement of the Bridge Marketing Period is
reasonably practicable in accordance with Section 6.09(b) of the Acquisition
Agreement).

 

3.             The
Sole Arranger shall have received reasonably satisfactory evidence that all
loans outstanding under, and all other amounts due in respect of, existing
indebtedness of the Borrower and its subsidiaries shall have been repaid in full
(or satisfactory arrangements shall have been made for such repayment) and the
commitments under all such indebtedness shall have been permanently terminated
and all liens and security interests related thereto have been permanently
released (other than the indebtedness and related liens (if any) described in
the next sentence). After giving effect to the Transactions, none of the
Borrower or any of its subsidiaries shall have outstanding any indebtedness
other than (a) the loans and other extensions of credit under the
Securitization Bridge Facilities, (b) capital lease obligations of the Borrower
and its subsidiaries to be agreed, (c) indebtedness in respect of the IHOP
Securitization incurred in connection with Series 2007-1, Series 2007-2 and
Series 2007-3 and (d) purchase money indebtedness, trade payables, capital
leases or letters of credit issued to support insurance policies, in each case,
in the ordinary course of business and other indebtedness permitted to be
incurred by the Acquired Business pursuant to the Acquisition Agreement as in
effect on the date hereof.

 

4.             The
Borrower shall have obtained all necessary consents and waivers in order for
the Borrower and its subsidiaries to consummate the Securitization Bridge
Facilities (including the

 

III-1

 

contemplated borrowings thereunder) and issue the Additional IHOP
Securitization Securities, each in form and substance reasonably satisfactory
to the Sole Arranger, and such consents and waivers shall be in full force and
effect. The Sole Arranger acknowledges that if FGIC provides consent to the
amendments and waivers to the IHOP Securitization on terms substantially
consistent with the terms of the Commitment Letter dated July 15, 2007 between IHOP
and FGIC as in effect on the date of the Commitment Letter (which letter has
previously been provided to the Sole Arranger), then such FGIC consent shall be
satisfactory to the Sole Arranger.

 

5.             The
Borrower shall have entered into one or more interest rate derivatives each
with an expiration date of not less than 12 months from the Closing Date in
form and substance acceptable to the Sole Arranger. The Sole Arranger
acknowledges that the form of derivative attached as Exhibit I to this
Commitment Letter is acceptable to the Sole Arranger.

 

6.             [Reserved.]

 

7.             The
Borrower shall have delivered to the Sole Arranger (a) audited consolidated
balance sheets and related statements of income, stockholders’ equity and cash
flows of each of the Borrower and the Target for the three most recently
completed fiscal years ended at least 90 days prior to the Closing Date, in
each case, prepared in accordance with GAAP, (b) unaudited consolidated
balance sheets and related statements of income, stockholders’ equity and cash
flows of each of the Borrower and the Target for each subsequent fiscal quarter
ended at least 45 days prior to the Closing Date (which shall have been
reviewed by the independent registered public accountants of the Borrower or
the Target, as applicable, as provided in Statement of Auditing Standards 100
and prepared in accordance with GAAP) and (c) a pro forma consolidated balance
sheet and related pro forma consolidated statement of income of the Borrower as
of and for the four fiscal quarter period ending on the last day of the most
recently completed fiscal quarter ended at least 45 days prior to the Closing
Date, prepared after giving effect to the Transactions as if the Transactions
had occurred as of such date (in the case of such balance sheet) or at the
beginning of such period (in the case of the statement of income), in each case
including such adjustments as the Borrower and the Sole Arranger mutually agree
are appropriate.

 

8.             [Reserved.]

 

9.             The
Sole Arranger shall have received a customary solvency certificate from the
chief financial officer for the Borrower.

 

10.           The
Sole Arranger, the Administrative Agent and the Initial Securitization Bridge
Lender shall have received all fees and expenses required to be paid on or
before the Closing Date.

 

11.           The
Collateral Agent shall have (or shall substantially simultaneously with the
Closing Date and the initial funding of the Securitization Bridge Facilities be
granted) (i) a first priority (subject to permitted encumbrances) lien on
and security interest in the Collateral with respect to the First Lien
Securitization Bridge Facilities and (ii) a second priority (subject to
permitted encumbrances, including the lien securing the First Lien
Securitization Bridge Facilities) lien on and security interest in the
Collateral with respect to the Second Lien Securitization Bridge Facility, in
each case as required in the Securitization Bridge Term Sheets under the
heading “Security”, all documents and instruments required to perfect such
security interests shall have been executed and be in proper form for filing; provided,
however, that with respect to any collateral (other than (x) the pledge
and perfection of the security interests in capital stock of U.S. subsidiaries
held by the Borrower or any Guarantor, (y) other assets pursuant to which a
lien may be perfected by the filing of a financing statement under the Uniform
Commercial Code and (z) owned intellectual property registered in the U.S.
Copyright Office or the U.S. Patent and Trademark Office pursuant to which a
lien may be perfected by the filing of an appropriate

 

III-2

 

notice of security interest in such office) that is not provided on the
Closing Date after the Borrower’s use of commercially reasonable best efforts
to do so, the delivery of such collateral shall not constitute a condition
precedent to the availability of the Securitization Bridge Facilities on the
Closing Date but shall be required to be delivered after the Closing Date in
accordance with the Securitization Bridge Term Sheets or pursuant to other
arrangements to be mutually agreed.

 

III-3

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00131-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00131-of-00352.parquet"}]]