Document:

<PAGE>

                                                             EXHIBIT 4(b)(ii).51

                Agreement on Provision of Services No. 621-487/01

Logica s.r.o.
having its registered office at Na okraji 335/42, 160 00 Praha 6
acting through
Logica s.r.o., organizacna zlozka
having its registered office at Tolsteho 9, 811 06 Bratislava
Identification No. (IC) : 0031795706
Tax Identification No. (DIC): 0031795706/602
Bank: Citibank Bratislava,  account No. 2003730008/8130
represented by Robert Sandor, director of an organizational part of an
enterprise

(hereinafter referred to as the "Provider")

and

Eurotel Bratislava, a.s.
having its registered office at Vajnorska 100/A, 831 03 Bratislava
represented by Jozef Barta, CEO and Procurator and JUDr. Jan Pitonak, Procurator
Identification No.:35 705 019 Tax Identification No.: 35705019
Bank: Tatrabanka,  account No. 2622021710/1100
Registered with Commercial Court Bratislava I, Section Sa, Insert no. 1238/B

(hereinafter referred to as the "Client")

In consideration of the obligations contained herein and with the intention to
be bound hereby, the contracting parties have agreed on the following wording of
the agreement:

1.    CONTRACTING PARTIES

      1.1.  The Provider declares that it is a legal entity duly organized and
            registered under the Slovak law in the Commercial Register
            administered by the District Court in Bratislava I, in section B,
            entry No. 758, and that it complies with any and all terms and
            conditions and requirements set out herein, and that it is
            authorized to conclude this Agreement and duly perform the
            obligations contained herein, and expressly declares that is
            authorized to grant licenses to use the software product according
            to this Agreement.

      1.2.  The Client declares that it is a legal entity duly organized and
            registered under the Slovak law in the Commercial Register
            administered by the Court in

<PAGE>

Agreement on Provision of Services             Logica s.r.o., organizacna zlozka
--------------------------------------------------------------------------------

            Bratislava in Section Sa, entry No. 1238/B and that it complies with
            any and all terms and conditions and requirements set out herein,
            and that it is authorized to conclude this Agreement and duly
            perform the obligations contained herein.

2.    SUBJECT OF THE AGREEMENT

      2.1.  The Provider hereby undertakes to provide the Client with services
            listed in Annex No. 1 (also called as the "Scope of Supply") hereto
            (hereinafter referred to as the "Services"); the Services provided
            by the Provider shall in no event be misinterpreted pursuant to the
            "Migration Study Document", dated November 7th, 2001 made by the
            Provider and accepted by the Client earlier to this Agreement and
            Project Plan attached as a separate Annex 3.

      2.2.  Client may request observance of additional standards or
            modification in accordance with standards as amended at the time of
            delivery, in the event of Client's interest in the services
            hereunder would otherwise be materially affected. In such case,
            Provider shall be entitled to demand appropriate additional
            compensation and a reasonable postponement of agreed delivery dates.

      2.3.  The Client hereby undertakes to provide assistance in a stipulated
            manner and to pay to the Provider the price agreed upon.

      2.4.  The description and scope of services are set out in Annex No. 1
            hereto.

      2.5.  Additional works or Change Requests as may be required by Client.

3.    PLACE AND DATE OF PERFORMANCE

      3.1.  The place of providing Services shall be the Client's registered
            office, unless otherwise expressly stated in Annex No. 2 hereto.

      3.2.  Dates of providing Services are set out in Annex No. 3 hereto,
            within the framework of the time-schedule of Project Plan, which has
            been agreed upon, or, as the case may be, set at a fixed date.

      3.3.  Delivery by Provider of the Services which are ready for Acceptance
            Testing by Client is expected to take place according to the
            schedule in Annex 3 and Annex 6 Acceptance Tests Procedure. Provider
            shall not unreasonably withhold acceptance. Should the delivery Date
            not be adhered to, Provider shall pay 0,25% penalty of the agreed
            price for the delayed deliverable for every complete week of delay,
            which is solely attributable to Provider up to a maximum of 5% of
            that price. However Provider shall have no liability for any failure
            to deliver to or delay in meeting the Delivery Dates agreed in the
            project plan unless such failure is solely caused by Provider. The
            liquidated damages shall only be due if Client is current with its
            payment hereunder.

                                      2/18

<PAGE>

Agreement on Provision of Services             Logica s.r.o., organizacna zlozka
--------------------------------------------------------------------------------

4.    PRICE AND PAYMENT TERMS AND CONDITIONS

      4.1.  The price of provision of the Services shall be as set out in Annex
            No. 4 hereto. Unless otherwise expressly stated therein, the price
            set out therein is exclusive of value added tax and reasonable
            expenses according to Annex No.4 hereto. In case, that Client shall
            be obliged to apply withholding tax, based on Double Taxation
            Avoidance Treaty between Czech and Slovak Republic, Client shall
            apply the withholding tax.

      4.2.  If Provider invoiced Client for services performed due to the
            Agreement on Provision of Services signed on December 21, 2001,
            payments to be provided according to Annex no. 4 hereto shall be
            deducted by the amount that the Provider already received for his
            performance to the Client under aforementioned Agreement concluded
            by and between the contracting parties and signed on December 21,
            2001. Such performance of the Provider is deemed to make a part of
            the performance of the Provider under this Agreement. The deduction
            has no influence to limitation liability amount according to 11.5
            hereof.

      4.3.  The Client undertakes to pay the price in individual installments
            determined in the payment schedule included in Annex No. 4 hereto.
            The price shall be payable in EURO, on the basis of invoices issued
            by the Provider in accordance with the payment schedule.

      4.3.  If such invoice does not contain all data required by the valid
            legal regulations or if the data are not stated correctly therein,
            the Client shall have the right to return such invoice to the
            Provider within ten (10) days of its receipt, with the
            identification of the prerequisites missing or incorrect data. In
            such event, the maturity period shall be interrupted and a new
            maturity period shall commence upon the delivery to the Client of
            the corrected invoice.

      4.4.  An invoice shall be deemed to have been delivered on the third (3rd)
            day from its evidenced mailing. Invoices are due in 30 days and
            shall be paid via bank transfer to the bank account of the other
            contracting party.

      4.5.  In the event of any delay with payment of a monetary amount, the
            contracting party which is in delay with payment shall pay the other
            contracting party 0,25% of the overdue payment for every complete
            week of delay, which is solely attributable tot he other party up to
            a maximum of 5% of that price.

5.    RIGHT TO USE AND INDEMNIFICATION

                                      3/18

<PAGE>

Agreement on Provision of Services             Logica s.r.o., organizacna zlozka
--------------------------------------------------------------------------------

      5.1.  If, on the basis of the performance by the Provider, the Client is
            to acquire the non-exclusive, non-transferable right to use to
            certain software (according to the Design Change Requests), the
            right to use shall pass to the Client on the date when the price of
            the performance is paid. The Client is entitled to use the said
            software only in compliance with its designation and subject to the
            conditions set out herein.

      5.2.  Provider, at its expense, shall defend and hold harmless and
            indemnify the Client against all and any claims by a third party
            whose intellectual property rights the Client has infringed by the
            use or installation of the software according to the Design Change
            Requests and/or any component thereof, in accordance with this
            Agreement; provided, however, that (i) Provider is promptly notified
            in writing of such claim, (ii) Provider shall have, to the maximum
            extent permitted under applicable law, the right to control the
            defense and/or settlement thereof, (iii) the Client furnishes to
            Provider on request all information available to the Client for such
            defense, and (iv) the Client will not admit any such claim and/or
            make any payments with respect to such claim without the prior
            written consent of Provider.

      5.3.  The risk of damage shall pass to the Client on the date of delivery
            of an item.

      5.4.  The Provider shall perform the services set forth herein through its
            employees or subcontractors. In case that the Provider is not the
            original holder of the right to use the work, the Provider shall
            ensure and obtain the consent to use the work for the purposes of
            this agreement of the work, from its employees or subcontractors.
            The costs for obtaining the consent are included in the price for
            the supply as agreed upon in this agreement. The consent granted
            either by the Provider or by its employees shall include consent to
            use the work for BSCS migration either performed by the Provider or
            any other third party.

      5.5.  The title and right to use the third party products will be granted
            to Client by Logica according to the license conditions for such
            third party products.

      5.6.  The Licensed Software (which consists of the standard BSCS Software
            and the Design Change Requests delivered hereunder) can only be used
            with the systems software, database software and hardware (the
            "System environment") recommended by Provider. In case of use under
            a different environment than the System environment, Provider shall
            not be liable for an warranty services. Warranty does not cover
            defects occurring as a result of operational errors or modification
            of the program on the part of the Client or any other third party.

      5.7.  Client shall immediately notify Provider in writing of any defects,
            specifying these exactly. Prerequisite for correcting the fault
            shall be Client describing the fault in co-operation with Provider,
            or stating how the fault makes itself noticed and what effect it
            has. The documents necessary to provide proof shall be, as far as
            possible, made available to Provider by Client. The parties shall
            work closely together to localize such defects.

      5.8.  Provider shall also be entitled to remedy defects by exchanging the
            work or a part thereof for another similar work.

                                      4/18

<PAGE>

Agreement on Provision of Services             Logica s.r.o., organizacna zlozka
--------------------------------------------------------------------------------

      5.9.  The Licensed Software shall be subject to a Software Service
            Agreement to be singed between the parties. The granting of rights
            to use in the Software Service Agreement does not cover models,
            methods, scripts, utility programs, program modules, program
            components such as libraries and other standard products used to
            fulfill this Agreement.

      5.10. Provider herewith acknowledge that Client shall not be entitled to
            rights of any kind whatsoever pertaining to materials, scripts,
            documents, schedules, designs, operating specifications or other
            documentation which may possibly be made available by Provider in
            connection with performance under this Agreement. Client shall not
            be entitled to reproduce these materials scripts, documents,
            schedules, designs operating specifications or other documentation
            nor to make these available to third parties in any form whatsoever
            nor use them for purposes beyond the execution of this Agreement.

      5.11. Upon termination of this Agreement, for any reason whatsoever,
            Client shall immediately surrender all materials, scripts,
            documents, schedules, designs, operating specifications or other
            documentation supplied by Provider or prepared by Provider. Client
            shall not be entitled to claim a right of retention of any kind with
            regard to the materials, documents, scripts, schedules, designs,
            operating specifications or other documentation.

6.    ADITIONAL CHANGE REQUESTS

      6.1.  Amendments to the Scope of Supply, which will become imperative due
            to Client's operational requirements, may not be rejected by
            Provider without providing a reason. When the parties agree to
            implement a change request to the Scope of Supply, the details of
            such change (scope, delivery dates, pricing) shall be specified and
            agreed in writing by the parties. Otherwise, Provider is not
            obligated to perform services in addition to the scope of services
            stipulated hereunder. Both parties shall make every effort to avoid
            additional effort, costs and postponements of delivery dates as far
            as possible.

      6.2.  Provider shall be entitled to invoice Client for any costs resulting
            from errors or omissions in the documentation or delays of
            deliveries supplied by Client or accepted by Client or resulting
            from incorrect written statements by Client employees.

      6.3.  Provider shall be entitled to invoice on a time and material basis
            at the prevailing Provider price list the cost of examining change
            requests as well as any preparation of functional specifications.
            Provider shall, however, give Client an initial non-binding estimate
            of the cost of a design change request (rough order of magnitude)
            prior to starting specification work.

7.    OBLIGATIONS TO CO-OPERATE

                                      5/18

<PAGE>

Agreement on Provision of Services             Logica s.r.o., organizacna zlozka
--------------------------------------------------------------------------------

      7.1.  The successful execution of software projects requires close
            co-operation amongst all parties concerned. Provider will not be
            able to render its software development and other services without
            co-operation from Client. Wherever possible, Provider shall draw the
            attention of Client to such co-operation requirements in good time,
            in order to facilitate operational planning for Client. Client shall
            provide all necessary co-operation services in such a way that
            delays to the project and hindrances to Provider shall be avoided.
            Client shall specifically provide the co-operation services set
            forth in Attachment 2 (Project Schedule).

      7.2.  If necessary, Client shall provide the information necessary to
            carry out the project as well as adequately qualified staff and
            persons to answer queries. Client shall draw the attention of
            Provider to requirements and practices specific to the Client and
            not specified in the Scope of Supply. Client shall supply the
            information and technical documentation in the form specified by
            Provider.

      7.3.  Client shall provide adequate space on Client's own premises for the
            personnel employed by Provider and shall allow them access to the
            rooms where hardware is installed or to the hardware on which the
            software is to be installed. Client shall make communications
            equipment such as telephone, fax, modem and data connections
            available at its own cost.

      7.4.  Co-operation activities, necessary decisions, approvals, comments on
            proposals or reservations, as well as confirmations of acceptance
            shall be issued and communicated by the Parties without delay.

      7.5.  Each party agrees that when its staff is present on the premises of
            the other party they shall comply with such rules and regulations as
            are notified to them for the conduct of staff on those premises.

      7.6.  Should Client fail to duly fulfill its obligations to co-operate,
            the contractually agreed execution dates shall be extended. The
            Parties understand that in view of Provider's personnel planning,
            delays may be excessive. Provider may charge any additional expense
            resulting from Client's default in cooperation, in particular for
            the prolonged provision of personnel, according to Provider's then
            prevailing time and materials rates. Provider shall, however, be
            obligated to notify Client about the additional expense beforehand,
            including the amount of the additional expense as reasonably
            foreseeable. Client shall then have the right to decide whether the
            services should be temporarily discontinued (and resumed after
            Client has fulfilled the co-operation obligation) or not. The
            Parties acknowledge that in case the services are discontinued,
            additional delay may be inevitable.

8.    ACCEPTANCE

      8.1.  At the request of the Provider, the Client shall inspect the work
            delivered by Provider under this Agreement and confirm acceptance of
            such work in writing.

                                      6/18

<PAGE>

Agreement on Provision of Services             Logica s.r.o., organizacna zlozka
--------------------------------------------------------------------------------

      8.2.  Defects, which do not materially prejudice the use of the work,
            shall not preclude acceptance. Such defects shall be noted in the
            acceptance report and corrected by Provider following acceptance.

      8.3.  Provider may request acceptance of definable partial deliverables
            and of interim results. Client shall be entitled to participate in
            any acceptance tests in whole or in part.

      8.4.  The acceptance procedure is described and will be led according to
            the Annex No. 6, Acceptance Procedure.

      8.5.  The Acceptance criteria will be defined in a Quality Plan, which is
            jointly agreed on, at the latest two weeks before the Acceptance of
            Functional Specifications.

      8.6.  Any part of the system or work performed by Provider used in
            commercial operation is deemed to be accepted.

9.    WARRANTY

9.1   The Provider warrants that:

      9.1.1 in making the Supply it shall exercise reasonable skill and care by
            personnel whose qualifications and experience will be appropriate
            for the tasks to which they are allocated;
      9.1.2 the deliverables will meet the requirements described in the
            documentation to it and tested successfully in the acceptance
            procedures;
      9.1.3 the Provider shall, free of charge, use all reasonable endeavors to
            remedy any breach of the warranty which is notified by the Client in
            writing during the warranty period.

9.2   The Client shall be obligated to notify the Provider without any
      unreasonable delay of any failure of the deliverables or any other
      non-compliance of the Provider with the Warranties. Should the Client fail
      to notify the Provider as set forth in the preceding sentence, the
      Provider shall not be responsible for any loss to the extent directly
      resulting from and after such failure.

9.3   The warranty period for products and services as per Annex 1 -Scope of
      Supply 1.2 and 1.2.1, expires (12) months after the date of acceptance of
      those deliverables.

9.4   The warranty period for products and services defined in Annex 1 - Scope
      of Supply 1.1, 1.2.2 and 1.3, expires (6) months after the date of
      Acceptance of those items, provided Client signs Support and Maintenance
      Agreement for Logica's part of the delivery to become valid and effective
      since the date of Acceptance. If the Support and Maintenance is not signed
      on the day one after the date of Acceptance at latest, the warranty period
      for those deliverables expires three (3) months after the date of their
      Acceptance.

9.5   The Licensed Software (which consists of the standard BSCS Software and
      the Design Change Requests delivered hereunder) can only be used with the
      systems

                                      7/18

<PAGE>

Agreement on Provision of Services             Logica s.r.o., organizacna zlozka
--------------------------------------------------------------------------------

      software, database software and hardware (the "System environment")
      recommended by Provider. In case of use under a different environment than
      the System environment, Provider shall not be liable for a warranty
      services. Warranty does not cover defects occurring as a result of
      operational errors or unauthorized modification of the program on the part
      of the Client or any other third party.

9.6   Client shall immediately notify Provider in writing of any defects,
      specifying these exactly. Prerequisite for correcting the fault shall be
      Client describing the fault in co-operation with Provider, or stating how
      the fault makes itself noticed and what effect it has. The documents
      necessary to provide proof shall be, as far as possible, made available to
      Provider by Client. The parties shall work closely together to localize
      such defects.

9.7   Provider shall also be entitled to remedy defects by exchanging the work
      or a part thereof for another similar work.

9.8   Until such time as the warranty services have definitively failed, Client
      may not demand a reduction of the remuneration for the work (deduction).
      Client may only terminate this Agreement (termination), if the warranty
      services have definitively failed with regard to at least three major
      software defects and, as a result of this, the use of the Licensed
      Software has become reasonably unacceptable for Client's customer.

9.9   The Licensed Software shall be subject to a Software Service Agreement to
      be singed between the parties. The terms and conditions of the Software
      Support Agreement shall be mutually agreed.

10.   AUTHORIZED PERSONS

10.1. Each contracting party shall appoint an authorized person. The authorized
      persons shall represent the contracting party in contractual and business
      matters related to the performance hereof. The authorized persons shall
      act on behalf the Parties only if they are entitled to do so under
      relevant corporate documents of the Parties, internal regulations of the
      Parties or respective power of attorneys, or as provided for by law. The
      Client shall notify the Provider without undue delay in writing of the
      persons which are entitled to act on behalf of the Client provided any
      legal actions will be necessary to perform.

10.2. The names of the authorized persons are listed in Annex No. 5 hereto. The
      contracting parties are authorized to make any change in the authorized
      persons, subject to a written notification thereof delivered to the other
      contracting party.

                                      8/18

<PAGE>

Agreement on Provision of Services             Logica s.r.o., organizacna zlozka
--------------------------------------------------------------------------------

11.   LIABILITY

11.1. Within the scope of valid legal regulations and this Agreement, the
      contracting parties shall be liable for damage caused resulting from
      grossly negligent conduct and intentional misconduct with no limitation.
      The contracting parties undertake to use their maximum effort to prevent
      damage and minimize damage occurred.

11.2. Neither contracting party shall be liable for damage resulting from a
      factually incorrect or otherwise erroneous order received from the other
      contracting party. Neither contracting party shall be liable for a delay
      resulting from any delay with the performance by the other contracting
      party of its obligations.

11.3. The contracting parties undertake to notify the other party, without undue
      delay, of any force majeure events preventing them from the due
      performance hereof. The contracting parties undertake to use their maximum
      effort to divert and overcome force majeure events.

11.4. Only the damage actually incurred shall be compensated. To the extent
      permitted by the valid legal regulations, none of the contracting parties
      shall be liable for any indirect, incidental or consequential damage,
      damage caused to data, or loss of profit or proceeds or other financial
      loss, including the damage resulting from a breach of obligations
      vis-a-vis any administrative authority, regardless of whether such damage
      results from a breach of a contractual obligation or any obligation set
      out by law.

11.5. The liability for damages that may arise from this Agreement shall consist
      from the amount which, until the origin of damage, has been paid hereunder
      as the price for performance but not more than 3.487.000 EUR

12.   PROTECTION OF INFORMATION

12.1. The contracting parties shall keep confidential any and all information
      they have obtained, in a usual manner for concealment of such information,
      unless otherwise expressly agreed. This confidentiality obligation shall
      survive the termination of effectiveness hereof. The contracting parties
      shall be entitled to request each other to document the sufficient
      concealment of confidential information. The contracting parties shall
      bind their employees, representatives, as well as other cooperating third
      parties with the same confidentiality obligation if such information has
      been disclosed to them.

12.2. Both contracting parties shall have the right to use, provide and disclose
      confidential information only to the extent and subject to the conditions
      necessary for the due performance of the rights and obligations arising
      from this Agreement.

12.3. The confidential information shall be deemed to be, regardless of the form
      in which it was obtained, any and all information which was not marked by
      any of the contracting parties as public information and which relates to
      this Agreement and its performance (in particular information regarding
      the rights and obligations of the contracting parties, as well as the
      information about prices), information which relates to any contracting
      party (in particular the trade secret, information regarding

                                      9/18

<PAGE>

Agreement on Provision of Services             Logica s.r.o., organizacna zlozka
--------------------------------------------------------------------------------

      their activities, structure, economic results, know-how), or information
      to which a special regime for concealment applies under the legal
      regulations (in particular the economic secret, state secret, bank secret,
      official secret). In addition to that, the confidential information shall
      be deemed to be any information, which is expressly marked as such by any
      contracting party.

12.4. Information which has become publicly available otherwise than as a result
      of a breach of a confidentiality obligation, information obtained on the
      basis of a procedure independent from this Agreement or the other
      contracting party, provided that the party which has obtained such
      information can document such fact, and, finally, information disclosed by
      a third party which has obtained such information without any breach of a
      confidentiality obligation, shall in no event be deemed to be confidential
      information.

12.5. None of the provisions hereof shall limit or prevent the Provider from
      publication or commercial use of any technical knowledge, skill or
      experience of a general nature, which it has obtained during the
      performance hereof.

13.   ASSISTANCE AND MUTUAL COMMUNICATION

13.1. The contracting parties undertake to provide each other with assistance
      and any and all information necessary for the due performance of their
      respective obligations. The contracting parties shall inform each other of
      any and all facts which are or may be important for the due performance of
      this Agreement.

13.2. The contracting parties shall perform their respective obligations arising
      from this Agreement in a manner preventing from the occurrence of any
      delay with meeting individual deadlines and any delay with meeting due
      dates of individual financial obligations

13.3. Any communication between the contracting parties shall be made through
      the authorized persons, empowered employees or statutory representatives
      of the contracting parties.

13.4. Any notices between the contracting parties which relate to or shall be
      made under this Agreement must be in writing and shall be delivered to the
      other party either in person or via a registered letter or another form of
      registered post communication to the address included in the title hereof,
      unless otherwise stipulated or agreed upon between the contracting
      parties.

13.5. Notices shall be deemed to have been delivered on the third (3rd) day from
      the date of their evidenced mailing.

13.6. If the Agreement requests that any document be delivered in a written
      form, such document may be delivered either in a hard copy or in an
      electronic (digital) form as a document prepared in the MS Word 6.0 or
      higher version text processor on an agreed medium.

13.7. In the case of any change in their addresses, the contracting parties
      undertake to notify the other contracting party thereof within three (3)
      days at the latest.

                                     10/18

<PAGE>

Agreement on Provision of Services             Logica s.r.o., organizacna zlozka
--------------------------------------------------------------------------------

14.   VALIDITY AND EFFECTIVENESS OF THE AGREEMENT

14.1. This Agreement shall become valid and effective on the date of its
      signature by both contracting parties.

14.2. Any contracting party shall have the right to give notice of termination
      of this Agreement for any reason whatsoever, or without stating a reason,
      and the notice period shall be six (6) months. The works performed by the
      Provider until the time, when Provider receives notice of termination and
      also works and products ordered until that time will be paid by Client.

14.3. Should the Provider be in default with performance for more than one (1)
      month and fail to remedy such situation even in the grace period of thirty
      (30) days from the date of delivery to it of the Client's written notice
      of such default, the Client shall have the right to rescind the Agreement.

14.4. Should the Client be in delay with payment of the Provider's invoices, and
      such delay lasts for more than thirty (30) days from the date of a written
      notice thereof, the Provider shall have the right to stop the works and
      rescind the Agreement; furthermore, the Provider shall have the right to
      rescind the Agreement if the Client defaults in the performance of its
      obligations hereunder for more than thirty (30) days and fails to remedy
      such situation even in the grace period of fifteen (15) days from the date
      of delivery to it of the Provider's notice of such default.

15.   DISPUTES RESOLUTION

15.1  The contractual parties undertake to make maximum efforts to remove mutual
      disputes arisen on the basis of this Contract or in connection with this
      Contract and to resolve them, in particular, with the aid of negotiations
      of contact persons or appointed representatives.

15.2  If the contractual parties fail to reach an agreement on the mode of
      resolution of the mutual dispute, either contracting party has the right
      to submit the dispute for arbitration proceedings to be realized according
      to the rules set out further. The party that enforces its rights in
      accordance with this Article 15.2 and sequentially, is pursuant party
      (plaintiff) and the other party is defendant. Notification must be
      accompanied by a proposal for the commencement of arbitration proceedings
      (action). A claim is made by the delivery of proper notification to the
      defendant.

15.3  The arbitration proceedings shall be held in Prague, in the Czech
      Republic.

15.4  Each of the contracting parties shall appoint one (1) person as arbitrator
      within fifteen (15) days of delivery of a written notice on opening of
      arbitration proceedings to defendant and this appointment shall announce
      to the other party and appointed

                                     11/18

<PAGE>

Agreement on Provision of Services             Logica s.r.o., organizacna zlozka
--------------------------------------------------------------------------------

      arbitrator; the plaintiff is responsible for the notification of the
      second arbitrator to the arbitrators, provided the defendant has complied
      with its obligation to appoint an arbitrator. The plaintiff may appoint an
      arbitrator in the notification under Section 15.2 If the defendant does
      not appoint an arbitrator by the stipulated deadline, the pursuant party
      may appoint this arbitrator.

15.5  The two arbitrators so appointed shall elect the third - presiding
      arbitrator within subsequent fifteen (15) days of the appointment of both
      arbitrators and shall announce this fact to both parties. If presiding
      arbitrator is not so appointed the arbitrators shall ask Chairman of
      Arbitration court administrated by Economic Chamber of the Czech Republic
      and Agrarian Chamber of the Czech Republic for his appointment.

15.6  The arbitrators designated under Section 15.2 may be replaced at any time
      by other persons subsequent to a unanimous agreement between the
      contracting parties for reasons of poor health, death or other serious
      reasons; if the presiding arbitrator has not yet been appointed the
      replacement is appointed by the party that appointed the outgoing
      arbitrator. If the parties do not agree on the appointment of a
      replacement arbitrator within 5 days, he shall be determined by the
      presiding arbitrator; if the presiding arbitrator is outgoing, the new
      arbitrator shall be appointed by the arbitrators. Newly appointed
      arbitrators shall go through the whole proceedings from the beginning.

15.7  The action shall include names and addresses of the contracting parties,
      the description of a claim, the amount claimed, and a proposal for dispute
      resolution.

15.8  The action, as delivered to the defendant under Section 15.2, shall be
      submitted to the presiding arbitrator, if he has been designated or
      appointed; if he has not yet been designated or appointed, the proposal
      for the commencement of arbitration proceedings shall be submitted to any
      designated arbitrator. The arbitrator shall mark the day he received the
      proposal on the proposal for the commencement of arbitration proceedings;
      the claim shall be regarded as having been made on this day, if it has not
      been possible to deliver the notification under Section 15.2 to the
      defendant. First the plaintiff may submit the proposal for the
      commencement of arbitration proceedings to the arbitrator it appointed, if
      it named him in the notification under Section 15.2, as of the day of
      delivery of the notification. The arbitrators shall conduct the
      arbitration proceedings as they see fit, although the contracting parties
      must have equal positions and must be provided with the same opportunity
      to present their opinions to the arbitrators. During proceedings each of
      the contracting parties has the right to require the arbitrators to
      conduct procedural hearings with the submission of evidence and
      questioning of witnesses, experts and the parties.

15.9  The plaintiff may only amend a proposal for the commencement of
      arbitration proceedings with the defendant's consent or, if a presiding
      arbitrator has been appointed, without the defendant's consent and with
      the consent of this arbitrator, who may reject the proposal if the results
      of proceedings conducted up to that point cannot be used for proceedings
      regarding the amended proposal.

15.10 Contractual parties can be represented by persons of their own selection.
      The names of representatives must be communicated in written to the other
      contractual party.

                                     12/18

<PAGE>

Agreement on Provision of Services             Logica s.r.o., organizacna zlozka
--------------------------------------------------------------------------------

      Any documents submitted to the arbitrators must be simultaneously
      delivered to the other party of the dispute.

15.11 The arbitrators shall sit eight (8) hours a day, six (6) days a week
      without interruption until they reach a decision.

15.12 The language of the arbitration proceedings shall be Czech. Written
      documents to be submitted by the contractual parties during the
      arbitration proceedings shall be translated into Czech, unless otherwise
      decided by the arbitrators in justified cases.

15.13 If an arbitrator is inactive, the parties shall proceed in a manner
      similar to that set out in Section 15.2; but if the inactive arbitrator is
      the one appointed by the defendant, the substitute arbitrator shall be
      designated by the plaintiff.

15.14 The remuneration of arbitrators shall be, as a matter of principle, always
      set out in advance, on the basis of a written agreement between the
      contracting parties. If the contracting parties do not agree on the
      remuneration the plaintiff will determine it with consent of arbitrators.
      The costs of the arbitration proceedings, i.e. the remuneration for
      arbitrators, administrative costs of arbitrators and legal fees shall be
      paid by the contracting parties according to their success in the matter.
      The party which is successful in the matter may claim reimbursement of the
      costs of the arbitration proceedings from the other party in a manner
      similar to that set out in provision of ss. 142 Section 1 to 3 of the Code
      of Civil Procedure. The arbitrators shall determine the amount of costs of
      the proceedings and their division and reimbursement in the award.

15.15 The arbitration award shall be final and binding for all parties and
      neither party shall apply to any authority for review thereof. The right
      of the contracting parties to apply to a court for nullification of the
      arbitration award or to propose cessation to the ordered enforcement of
      the award in accordance with law is not hereby affected.

15.16 The pursuant party may, instead of the procedure set out in Section 15.2,
      submit an action to a municipal court or the Court of Arbitration of the
      Economic Chamber of the Czech Republic and the Agrarian Chamber of the
      Czech Republic; if the first act for the commencement of arbitration
      proceedings has already been taken (Section 15.2), it may do so only
      subsequent to a written agreement or if the presiding arbitrator has not
      been appointed, even by the procedure set out in the second sentence of
      Section 15.2.

15.17 In the event that disputes between the contractual parties are resolved by
      a court, the relevant court shall be in Prague.

16.   FINAL PROVISIONS

16.1. Unless otherwise provided in this Agreement the priority of the Agreement
      documents shall be as follows:

            1.    This Agreement including the terms and conditions of the
                  Agreement
            2.    The Annexe(s)
            3.    Any other documents mentioned in the Agreement

                                     13/18

<PAGE>

Agreement on Provision of Services             Logica s.r.o., organizacna zlozka
--------------------------------------------------------------------------------

      In case of any discrepancy between the above documents the text of this
      Agreement shall always prevail over any of the Annexes except the
      Agreement itself. Each Annex shall prevail over the documents referenced
      in said Annex. Later made addendums and amendments alter the contents of
      this Agreement only to the extent expressly agreed upon between the
      parties; all other conditions shall always remain unchanged.

      As the Annexes constitute an integral part of the Agreement, any breach or
      infringement of whichever duty, obligation or commitment of either Party
      shall be deemed as breach or infringement of the Agreement and shall
      invoke corresponding consequences.

16.2  This Agreement, as well as the rights and obligations arising from or in
      relation with this Agreement, shall be governed by the law of Austria with
      giving no effect to the conflicts-of-law provisions thereof.This Agreement
      represents the entire agreement between the contracting parties in respect
      to the subject hereof. The Agreement on Provision of Services agreed on by
      and between the parties and signed on December 21, 2001 shall be replaced
      by this Agreement from the date of its effectiveness.

16.3  This Agreement may only be amended by a written agreement between the
      contracting parties in the form of numbered amendments hereto, signed by
      authorized representatives of both contracting parties.

16.4  The following annexes constitute an integral part of this Agreement:

             Annex No. 1   Specification of the Services Provided
             Annex No. 2   Place of Delivery
             Annex No. 3   Date of Delivery
             Annex No. 4   Price and Payment Schedule
             Annex No. 5   Authorized Persons
             Annex No. 6   Acceptance Procedure
             Annex No. 7   Responsibilities List

16.5  This Agreement has been executed in four (4) counterparts, and each
      contracting party shall receive two (2) counterparts.

 The parties declare that they have read this Agreement, that they agree to its
      contents and in witness thereof, they affix their signatures hereto:

               Logica, s.r.o                     EuroTel Bratislava, a.s.
        In Bratislava, on 12.2.2002            In Bratislava, on 12.2.2002

        ..............__.__.______          __.__.______........................

           ----------------------                 -------------------------
                Robert Sandor                             Jozef Barta
                                                       CEO and Procurator

                                                  -------------------------
                                                       JUDr.Jan Pitonak
                                                          Procurator

                                     14/18

<PAGE>

Agreement on Provision of Services             Logica s.r.o., organizacna zlozka
--------------------------------------------------------------------------------

                                     15/18

<PAGE>

Annex No. 1

Specification of Services Provided

1.1   Professional Services

      The following Professional Services:

      -     Management Services:

            -     Project Management;
            -     Technical Management;
            -     Integration Test Management;
            -     Acceptance Management;
            -     Data Migration Management;
            -     Cutover Management;

      -     Database Administration;

      -     Baseline Configuration;

      -     Integration Testing;

                  .     Site Acceptance Testing;

      -     Data and rate plan migration;

      -     Cutover support encompassing a dry run of a full migration as well
            as the actual migration to allow the system to go into production;

      -     20 man days of hot run support when the migrated system first enters
            production.

      -     Consultancy for requirement 141

      -     Consultancy services (20 days maximum), including the support of
            EuroTel to upgrade the existing reporting interfaces related to
            requirements 037, 046, 053, 054, 070, 071, 125, 144, 145, 170, 171,
            172, 173, 178, and 990.

1.2   Software deliverables

      BSCS Version 6.1 running on current version of Oracle 8.1.7 and Dec 5.1
      will be delivered and installed on the production server.

      The modules delivered will be:

      -     BSCS v6.1 Standard online executable modules;
      -     BSCS v6.1 Kernel batch executable modules;
      -     DCR 162, Unapplied Cash Handler (UCH);
      -     DCR 117, Support for the service 'Minutes';
      -     Customer Administration Server modul and CAS Service Layer
            interface;

<PAGE>

      -     CAS Package 2.

1.2.1 BSCS Modules

      The solution uses modules in BSCS to cover the following functionality:

      -     Customer care;
      -     Accounts receivable, cash drawer;
      -     Services and tariffs;
      -     Motivations and incentives;
      -     International roaming (using standard BSCS v6 functionality based on
            the TAP 3 standard);
      -     External carriers;
      -     Discounting, motivations and incentives;
      -     Call rating and billing;
      -     Resource management;
      -     Collections;
      -     Dealer management.

1.2.2 Custom developments

      Custom developments by Logica for EuroTel of the interfaces defined in the
      Functional Specifications. This includes the following interfaces:

      -     Resource Admin to SIM vendors
      -     TAP3 support via BMP
      -     Comptel SAS provisioning
      -     PIH
      -     SBGH interface to DOC1
      -     Datawarehouse
      -     IN-VPN

                                      2/5

<PAGE>

1.3   Documents Deliverables

1.3.1 BSCS documentation

            =================================================================
                             Document                        Type of
                                                             document
            -----------------------------------------------------------------
            Accounts Receivable                         User Manual
            -----------------------------------------------------------------
            Customer Administration                     User Manual
            -----------------------------------------------------------------
            Customer Administration Server              User Manual
            -----------------------------------------------------------------
            Equipment Identify Register                 User Manual
            -----------------------------------------------------------------
            External Carriers                           User Manual
            -----------------------------------------------------------------
            External Interface                          User Manual
            -----------------------------------------------------------------
            General Ledger                              User Manual
            -----------------------------------------------------------------
            Inter-exchange Carrier                      User Manual
            -----------------------------------------------------------------
            International Roaming                       User Manual
            -----------------------------------------------------------------
            Reference Data                              User Manual
            -----------------------------------------------------------------
            Report Manager                              User Manual
            -----------------------------------------------------------------
            Resource Administration                     User Manual
            -----------------------------------------------------------------
            Sales Administration                        User Manual
            -----------------------------------------------------------------
            Service & Tariffs                           User Manual
            -----------------------------------------------------------------
            Service Provider                            User Manual
            -----------------------------------------------------------------
            System Administration                       User Manual
            -----------------------------------------------------------------
            Translation Administration                  User Manual
            -----------------------------------------------------------------
            Batch Operators Manual                      Operators Guide
            -----------------------------------------------------------------
            BSCS Interfaces Description                 System Doc.
            -----------------------------------------------------------------
            BSCS Version 6.1 Shipment Notes             System Doc.
            -----------------------------------------------------------------
            Configuration Guide                         System Doc.
            -----------------------------------------------------------------
            Installation Guide                          System Doc.
            -----------------------------------------------------------------
            Release Guide Version 6.1                   Release Guide
            -----------------------------------------------------------------
            Data Base Dictionary                        Table Reference
            =================================================================

      Table 1.1 - Contractually Deliverable BSCS Documents

      According to the Functional Specification (FSP) and High Level Design
      (HLD) documents the Schlumberger SemaVision BSCS V6.0 online help texts
      and user manuals will be adapted.

<PAGE>

1.3.2 Project documentation

      The table below shows the documents to be delivered by Logica. It also
      identifies:

      -     Whether EuroTel approval is required for the document;
      -     Milestones directly related to the document, if any. The planned
            delivery dates for the document can then be found by
            cross-referencing the milestone in Appendix B.

      --------------------------------------------------------------------------
      Id                        Title                      EuroTel     Milestone
                                                          Approval
      --------------------------------------------------------------------------
       1    One set of standard BSCS documentation            No          N/A
            on CD-ROM and hard copy
      --------------------------------------------------------------------------
       2    Project Plan                                     Yes         DM-1
      --------------------------------------------------------------------------
       3    Quality Plan                                     Yes         DM-2
      --------------------------------------------------------------------------
       4    User Requirement Matrix                          Yes         DM-3
      --------------------------------------------------------------------------
       5    Functional Specifications for the following      Yes         DM-4
            interfaces:

            -     Resource Admin to SIM vendors
                  UTX to UDR and TAP3 to UDR mapping
            -     TAP3 support via BMP
            -     Comptel SAS provisioning
            -     PIH
            -     SBGH interface to DOC1
            -     Datawarehouse
            -     IN-VPN

      --------------------------------------------------------------------------
       6     Configuration Plan                              Yes         DM-5
      --------------------------------------------------------------------------
       9     Acceptance Test Plan                            Yes         DM-8
      --------------------------------------------------------------------------
       10    Acceptance Test Specifications                  Yes         DM-9
      --------------------------------------------------------------------------
       11    Cutover Plan                                    Yes        DM-10
      --------------------------------------------------------------------------
       12    Client Progress Report                          No        Monthly
      --------------------------------------------------------------------------

      Table 1.2 - Contractually Deliverable Documents

      For documents to be approved by the Client, EuroTel are required to
      provide review comments on draft versions of deliverable documentation
      within five working days of receipt of that documentation. Such period may
      be shortened or extended by mutual agreement of the parties on a
      case-by-case basis.

                                      4/5

<PAGE>

1.4   Data Migration Deliverables

      The BSCS subscriber and financial data will be migrated to version 6.1
      database. The scope of migration will be discussed in detail during the
      analysis phase of the project. The general assumption is that customer
      data and rate plans will be migrated. The number of migrated rateplans
      will be that of accepted during the acceptance tests; therefore rateplans
      will have to be frozen four weeks before acceptance tests.

1.5   Not delivered

      Logica is not delivering the following:

      -     The development, integration, migration, acceptance and production
            hardware platform;
      -     System software, other than BSCS v6.1, associated with EuroTel's
            development, test and production hardware, e.g. Oracle, operating
            system, development tools and applications, etc.
      -     Interfaces customisations to systems or interfaces not previously
            listed in section 1.2.2.

<PAGE>

      Annex 4: Price and Payment Schedule

1.1   Fixed price package

      The fixed price for the Migration project is (Euro)3,486,905 (exclusive of
      VAT and travel and accommodation costs). The price should be paid
      according milestones clearly defined in the project plan. Payment schedule
      is based on the sizing of the workload in different phases of migration
      project and on the guarantees given to EuroTel in form of the last
      installments to be paid after the final acceptance.

1.1.1 Payment schedule:

       PM-1  Contract signature                                              30%
       PM-2  First qualified shipment                                        25%
       PM-3  First qualified shipment with zero quality defect               20%
       PM-4  Acceptance                                                      20%
       PM-5  End of hot-run support                                           5%

1.1.2 Logica Development Price

      --------------------------------------------------------------------------
      Description                                                Estimated Price
                                                                 (Euro)
      --------------------------------------------------------------------------
      Custom developments of non-kernel modules
      covering the following EuroTel Bratislava
      requirements: 142, 069, 121, 140, 149, 163,
      177, 991 and consultancy in development to
      be provided by Eurotel for following
      requirements: 037, 046, 053, 054, 070, 071,
      125, 144, 145, 170, 171, 172, 173, 178, 990.
      The consultancy is limited to 20 man days.
      ----------------------------------------------
      Logica effort for overall project
      co-ordination, system integration testing,
      acceptance testing, cutover, 20 working days
      Hot run support.
      --------------------------------------------------------------------------
      Total:                                                        1,511,500
      --------------------------------------------------------------------------

1.1.3 SchlumbergerSema Development Price

      --------------------------------------------------------------------------
      Description                                       Estimated Price (Euro)
      --------------------------------------------------------------------------
      Customer Product Development (DCR: 162,
      117, CAS P 2)
      --------------------------------------------------------------------------

<PAGE>

      --------------------------------------------------------------------------
      Data Migration: Design and Development and
      related Project Management, Quality
      Management, Installation support and
      Documentation
      --------------------------------------------------------------------------
      Total                                                         1,531,705
      --------------------------------------------------------------------------

1.1.4 Additional DCRs and scope of work:

      --------------------------------------------------------------------------
      Description                                            Price (Euro)
      --------------------------------------------------------------------------
      DWH, MDS/SAS, TurboFlex, Document
      management, BMP                                                443,700
      --------------------------------------------------------------------------

            Prices are exclusive of VAT, all other applicable taxes and travel
            expenses: of Provider and SchlumbergerSEMA staff.

1.2   Expenses

      Expenses related to performed services include travelling, lodging, per
      diem and travelling time of Logica and SchlumbergerSEMA professional
      staff. Traveling time is charged 50% of working time. Provider's
      employees and subcontractors are entitled to travel to their respective
      home locations on a weekly basis, flights and accomodation in a business
      class limited by the price (Euro)130 per night. Logica CZ staff is
      entitled to use car or train for the travelling to the place of delivery
      and standard hotel or adequate accommodation limited by price (Euro)100
      per night. All staff is allowed to charge for additional expenses, like
      taxifrom the airport or railway station and hotel to the place of
      delivery. Expenses will be charged and invoiced separately, in relevant
      currency, on a monthly basis. Invoices are due in 30 days.

<PAGE>

Annex No. 2

Place of Delivery

The place of delivery is Eurotel Bratislava, a.s., location at Vajnorska 100/a
Bratislava.

                                      1/1

                                            Appendix 2 - Place of delivery C.doc

<PAGE>

Annex No. 7:List of responsibilities

1.1   Logica

      Deliver:

      -     Professional services

      -     Custom developments

      -     Project documentation

      according to the Appendix A Chapters 1.1, 1.2.2, and 1.3.2 respectively
      within the timeframe agreed in the DM-1 Project plan document keeping the
      quality constrains as specified in DM-2 Quality plan document.

1.2   SchlumbergerSema

      Deliver:

      -     Functional specification and binaries of BSCS v6 customized software

      -     BSCS documentation

      -     Data migration

      -     Ordered professional services (testing, acceptance, cut-over)

      according to the Appendix A Chapters 1.2, 1.3.1, and 1.4 respectively
      within the timeframe agreed in the DM-1 Project plan document according to
      the SchlumbergerSema internal quality standards.

1.3   EuroTel Bratislava

      The table below shows the contractually agreed dependencies on EuroTel to
      allow Logica to meet the requirements of the CONTRACT.

      Any delay by EuroTel in meeting these dependencies entitles Logica to
      delay its corresponding obligations for a period equal to the duration of
      such delay.

      The status of dependencies as shown in the table below represents a
      snapshot at the time of production of the current issue of this plan.
      Changes and updates are reported in the client progress reports.

      ==========================================================================
      No.   Obligation                                            Plan Due
                                                                  Date
      --------------------------------------------------------------------------
      1.    To have permanent office space made                   Project start
            available to
      ==========================================================================

                                      1/5

<PAGE>

      ==========================================================================
      No.   Obligation                                            Plan Due
                                                                  Date
      --------------------------------------------------------------------------
            support 10 Project start Logica/Sema
            staff. This office space does not
            cover space needed for 3rd party
            developers (e.g. Oracle, CGEY).
      --------------------------------------------------------------------------
      2.    Appoint an internal Project Manager to                Throughout
            co-ordinate all EuroTel activities and
            to ensure that all EuroTel decisions
            are taken in a timely manner and in
            accordance with the project schedule.
            The EuroTel Project Manager shall be a
            single point of contact with Logica's
            Project Manager. The EuroTel Project
            Manager shall attend regular (weekly)
            progress meetings with the Logica
            Project Manager. The EuroTel Project
            Manager shall review Logica's monthly
            progress report and take full
            appropriate action in respect of
            issues.
      --------------------------------------------------------------------------
      3.    Technical support (PC, networks,                      Project start
            printers, software, email etc.) and
            system administration support for the
            Logica project team. Appoint an
            experienced system administrator/ DBA
            to support Logica's DBA.
      --------------------------------------------------------------------------
      4.    EuroTel will deliver a DB dump to Sema                Project start
      --------------------------------------------------------------------------
      5.    EuroTel to agree the scope of the                     During the
            system based upon Functional                          first month of
            Specifications within 5 working days                  project
            of receipt. Since the FS is expected
            to be a bulky document, particular
            parts will be provided to EuroTel in
            the meantime in a 'draft' state so the
            most of the document can be reviewed
            even before the official delivery.
            Provide subject matter experts for
            workshops and a list of business
            process owners and application
            architects (and their availability)
            within EuroTel for Logica consultants
            to discuss interface requirements and
            business processes and agree dates for
            consultation.
      --------------------------------------------------------------------------
      6.    Development hardware and environment                  2 weeks from
            to be made available within 2 weeks of                the project
            the project start.                                    start
      --------------------------------------------------------------------------
      7.    Testing/production hardware available.                Two/six weeks
                                                                  from the
                                                                  project start
      --------------------------------------------------------------------------
      8.    EuroTel shall provide Logica with                     2 weeks from
            example files for testing of all the                  the project
            interfaces defined in the Functional                  start
            Specifications.
      --------------------------------------------------------------------------
      9.    All formal documentation must be                      Throughout
            reviewed and agreed within five
            working days upon receipt.
      --------------------------------------------------------------------------
      10.   EuroTel must continuously have a valid                Continuous
            maintenance agreement in place for the
            BSCS system to be
      ==========================================================================

<PAGE>
      ==========================================================================
      No.   Obligation                                            Plan Due
                                                                  Date
      --------------------------------------------------------------------------
            entitled to the V6.1 licence upgrade.
      --------------------------------------------------------------------------
      11.   EuroTel will assign qualified and                     Throughout
            appropriate staff for integration and
            acceptation tests, and cutover.
      --------------------------------------------------------------------------
      12.   EuroTel Bratislava will freeze its HW                 2 weeks from
            and SW production platform                            the project
                                                                  start
      ==========================================================================

                         Table 3.2 - Client Dependencies

      Monitoring and reporting of dependencies will be reviewed on a
      regular basis, at least monthly, with the client Project Manager
      and Logica line management. The vehicle for this review will be
      the Project Status reports.

1.3.1 EuroTel Bratislava Dependencies

      Logica is convinced that the project will be successful if the end users
      and EuroTel Bratislava team are fully committed to working together with
      Logica towards the delivery. There are number of obligations which EuroTel
      must meet to ensure project success. The exact specification and dates
      when the obligations must be met will be finalized in a contract
      negotiation phase and the Project Plan, however the key obligations are as
      follows:

      ==========================================================================
      No.   Obligation
      ==========================================================================
      1.    Provide an authorization to formally proceed with the project in
            accordance with the scope as outlined in this document.
      --------------------------------------------------------------------------
      2.    Agreed contract between EuroTel Bratislava and Logica.
      --------------------------------------------------------------------------
      3.    Agreed scope of supply.
      --------------------------------------------------------------------------
      4.    Appoint EuroTel Bratislava full-time Project Manager prior to
            project start to co-ordinate all EuroTel Bratislava activities and
            to ensure that all EuroTel Bratislava decisions are taken.
      --------------------------------------------------------------------------
      5.    Appoint one Consultant to work full time on the project under Logica
            project management. Appoint a programmer experienced in the
            particular area to work full time on the project under Logica
            project management.
      --------------------------------------------------------------------------
      6.    Appoint EuroTel Bratislava experienced system administrator/DBA to
            support Logica's onsite system administrator/DBA and to support data
            migration activity.
      --------------------------------------------------------------------------
      7.    Provide subject matter experts for workshops and a list of business
            process owners and application architects (and their availability)
            within EuroTel Bratislava for Logica consultants.
      --------------------------------------------------------------------------
      8.    Identify staff responsible, and ensure their availability, for
            review and acceptance of deliverables in a timely manner.
      --------------------------------------------------------------------------
      9.    Provide all information requested by Logica and/or Sema in the
            project language (English) in a timely manner. When requesting a
            particular information element, the project manager will assign a
            latest
      ==========================================================================

<PAGE>

      ==========================================================================
            date for delivery of this information that is not unreasonably soon.
            EuroTel Bratislava typically will be expected and shall make sure to
            answer information requests within two weeks or less for major
            requests and business decisions involving EuroTel Bratislava and
            within three days for smaller details.
      --------------------------------------------------------------------------
      10.   Provide any documentation necessary for a scheduled activity in
            English at start of the activity. The Logica/Sema project manager
            will advise the EuroTel Bratislava project manager of required
            information. However, EuroTel Bratislava shall ensure the delivery
            of a complete, accurate and up-to-date set of documentation.
      --------------------------------------------------------------------------
      11.   Provide an overview and technical documentation about interfaces
            that have to be supported by the application in English at project
            start.
      --------------------------------------------------------------------------
      12.   Provide a test environment to support data migration testing, system
            integration test, acceptance test and training for both Logica and
            its sub-contractors. Environment should be ready for BSCS
            installation, i.e. operating system installed, Oracle installed,
            network interfaces configured.
      --------------------------------------------------------------------------
      13.   Provide a fully installed and configured hardware, and system
            software production environment.
      --------------------------------------------------------------------------
      14.   Provide system software, other than BSCS v6.1, associated with
            EuroTel Bratislava's test and production hardware, e.g. Oracle,
            operating system, bill print viewer. Install client PC software in
            production environment.
      --------------------------------------------------------------------------
      15.   Provide review comments on draft versions of deliverable
            documentation within one week of receipt of that documentation. Such
            period may be shortened or extended by mutual agreement of the
            parties on a case-by-case basis.
      --------------------------------------------------------------------------
      16.   Provide office accommodation, necessary (sufficiently private)
            workspace, conference rooms PCs, access to network printing, file
            servers, etc., direct dial international phone access, data
            communication capabilities to allow remote diagnostics and data
            transfer, web access, for Logica and Sema while on EuroTel
            Bratislava premises.
      --------------------------------------------------------------------------
      17.   Ensure the cooperation of third parties like network equipment
            manufactures, etc.
      --------------------------------------------------------------------------
      18.   Ensure that EuroTel Bratislava specialist have the appropriate
            knowledge of BSCS v6.1 knowledge.
      --------------------------------------------------------------------------
      19.   Provide live data required for system integration testing, Provide
            access to the production database to compare the results of
            processing the live data in both the source and target databases.
      ==========================================================================

<PAGE>

1.3.2 EuroTel Custom Deliverables

      The IT department of EuroTel will be responsible for the updating of
      various interfaces and reporting applications as part of the overall
      migration implementation. EuroTel Bratislava will be responsible for
      timely delivery of.

      -     The upgrade of the applications interfacing with BSCS, i.e. EuroTel
            own applications and third party applications.
      -     Design of CAS clients or modification of existing EuroTel satellite
            applications to communicate with the CAS server.

      The necessary support to be provided by Logica in relation to this work is
      to be agreed along with the relevant milestones in the review of the
      Logica proposal.

<PAGE>

                                                                          logica

Annex 6: Acceptance test procedure

1.1         Introduction

            The tests will be performed in three stages:

            -     Unit tests (Chapter 1.3.1 of this document)

            -     Integration tests (Chapter 1.4 of this document)

            -     Acceptance tests (Chapter 1.5 of this document)

            Each of these tests will be performed according to a test
            specification prepared in advance according rules stated below.
            EuroTel Bratislava will be responsible for approval of the
            Acceptance Tests Plan and Acceptance Test Specifications (project
            deliverables DM-8 and DM-9 respectively).

            The successful performance of Acceptation tests is a precondition to
            the project milestone PM-4.

1.1.1       Responsibilities

            All parties involved in the project (Logica, SchlumbergerSema, and
            EuroTel Bratislava) must participate in the respective tests of the
            delivered modules:

1.1.1.1     Logica

            -     Quality plan defining test documentation

            -     Unit tests of non-kernel DCRs

            -     Integration tests plan

            -     Integration tests specification (non-kernel)

            -     Integration tests

            -     Acceptation tests plan

            -     Acceptation tests specification

            -     Acceptation tests

1.1.1.2     SchlumbergerSema

            -     Unit tests of kernel DCRs and CAS2

            -     Integration tests plan for kernel and CS2 packages

            -     Integration tests specification (kernel, CAS2)

Appendix 6 - Acceptance procedure C.doc   1/8  Appendix 6 - Acceptance procedure
                                                                           C.DOC
(C) 2001 Logica

<PAGE>

EuroTel Bratislava - BSCS Migration Study -
Migration Study Document ECF0548:002/Accepted D
2002-01-09

1.1.1.3     EuroTel Bratislava

            -     Approval of tests specification

            -     Preparation of tests environment

            -     Attendance of all performed tests

            -     Tests results approval

1.2         Test documentation

            The Test Transmittal Report is used to identify the items being
            transmitted for testing. Its use may be defined in the project
            quality plan and would normally be specified where formal
            transmittal of a test baseline between environments or some formal
            approval is needed.

            The Test Log is used to provide a complete list, in chronological
            order, of the tests performed and their status. Its use would be
            specified in the project quality plan. Where test results are
            recorded in some other format - e.g. by annotating a copy of the
            test description - then the additional status information identified
            in the template below should be recorded, i.e. baseline tested, date
            and time of test, tester and system configuration details.

            The purpose of Test Defect Observation Report is that of formally
            recording any defect or anomaly identified during inspection or
            testing of a unit, build or system. Its format is based on the
            general observation report and its use is mandatory for all formal
            testing. Besides describing the defect, the observation should
            identify the severity of the problem, other units affected, relevant
            change requests and be formally closed when corrected.

            The Test Summary Report is used to summarise the results of the test
            stage and to provide evaluations for those results. Its use should
            be described in the project quality plan. It is used to show
            approved completion and analysis of all formal testing.

            The Unit Test Description is a mandated output. It has a recommended
            format which is described in Cortex. It has a minimum mandated
            coverage which is described below:

            -     Identity of the unit to be tested

            -     The test objective

            -     The techniques to be applied

            -     The coverage criterion to be used

2                                        APPENDIX 6 - ACCEPTANCE PROCEDURE C.DOC
                                                          (C) 2002 Logica s.r.o.
                                                 General-OD template version 1.1

<PAGE>

EuroTel Bratislava - BSCS Migration Study -
Migration Study Document ECF0548:002/Accepted E
2002-01-09

            -     A listing of test cases to be applied, showing for each the
                  inputs and expected outputs

            -     The test expected results

            -     The pass/fail criteria

            -     The hardware and software environment

            The Integration and System Test Plan is a mandated output. It has a
            recommended format, which is described in Cortex.

            The Integration and System Test Specification is a mandated output.
            It has a recommended format, which is described in Cortex.

            The Acceptance Test Plan is a mandatory output.

            The Acceptance Test Specification is a mandatory output.

            The Acceptance Test Description is a mandatory output. It has a
            recommended format, which is described in the Cortex. The
            description of an acceptance test should include the following
            topics:

            -     Unique test identifier and title

            -     Purpose which describes why the test is performed

            -     Time estimate for the test

            -     Resources: e.g. PCs, printers, simulators, any special test
                  equipment

            -     Dependencies: tests which must be executed before this one

            -     Any preconditions for the test, such as database contents

            -     Procedure: describes, in a series of steps, the actions to
                  execute the test and the expected system response, down to the
                  level of the transaction executed and a which type of
                  terminal. This will also define a clear unambiguous pass or
                  fail criteria for each high level step. These criteria are
                  critical because it is the passing of these criteria that
                  determine if the test passes or not

            -     Any tidying up activity required after the test

            -     Functions covered.

            An Acceptance Certificate is a mandatory output. The requirements
            for format, content, issue, authorisation and agreement of
            Acceptance Certificates under a contract is defined in the Quality
            Plan.

APPENDIX 6 - ACCEPTANCE PROCEDURE C.DOC                                        3
(C) 2002 Logica s.r.o.
General-OD template version 1.1

<PAGE>

EuroTel Bratislava - BSCS Migration Study -
Migration Study Document ECF0548:002/Accepted D
2002-01-09

1.3         Test design

1.3.1       Unit tests

            A Unit Test Description in the form required by Cortex and is
            produced for each Unit specification. Testing of an object is
            complete only when all defined test cases have been executed and the
            results have been reviewed against the expected results and the
            criteria for success. Unit test is complete once all units
            identified in the Technical Specification have been tested, and a
            complete set of software source code or hardware assemblies, Unit
            Test Descriptions and test results have been placed under
            configuration control. Testing corrected errors and enhancements is
            performed according to this process. In such cases regression
            testing has to be also performed.

1.3.2       Test Aims

            -     To demonstrate that an objects satisfies the stated
                  requirements of its functional design and construction
                  criteria.

            -     To confirm that an object is appropriate for its intended
                  purpose and usage

            -     To record the execution and results of the tests conducted.

            -     To provide a definitive and repeatable verification and
                  validation process with deterministic results.

1.3.3       Exit criteria

            -     Verified and validated object placed under configuration
                  control.

            -     Completion of all defined unit test cases and review of
                  results, (or decision to abandon).

1.3.4       Outputs

            -     Unit Test Description

            -     Test Results

            -     Test Transmittal Report

            -     Test Log

            -     Test Defect Observation Report

            -     Test Summary Report

4                                        APPENDIX 6 - ACCEPTANCE PROCEDURE C.DOC
                                                          (C) 2002 Logica s.r.o.
                                                 General-OD template version 1.1

<PAGE>

EuroTel Bratislava - BSCS Migration Study -
Migration Study Document ECF0548:002/Accepted E
2002-01-09

1.4         Integrate and (Sub)System Test

            This sub-process covers the building and testing of the system from
            its smallest building blocks; i.e. hardware and software units.
            During the process, errors are discovered and removed. The
            sub-process covers processes, which can be exercised individually in
            sequence, or collectively, dependent on the scope defined Functional
            Design.

            An Integration and Test Plan is produced to define the strategy and
            approach used for integrating and testing software and hardware
            components to build the unit or system, and for conducting overall
            system tests of that unit or system.

            System Tests must relate to, and be traceable to, the Technical
            Specification. The integrate and test process could be applied
            recursively. Completion of the above processes is achieved once all
            tests specified in the Integration and System Test Specification
            have been executed and passed, and the results are under
            configuration control.

1.4.1       Integration test principles

            The integration process commences with building units into the
            planned components of the system. The following principles apply:

            -     The test environment must be controlled and stable

            -     Test assemblages for integration testing must have been
                  constructed from configuration controlled copies that have
                  passed their unit tests

            -     Support software and hardware must be suitably validated prior
                  to use and maintained under configuration control

            -     Integration tests will be divided for the two tests sets:

                        -     Kernel parts

                        -     Non-kernel parts

1.4.2       Integration test responsibilities

            SchlumbergerSema is responsible for integration tests for kernel
            parts. Logica is responsible for integration tests for non-kernel
            parts.

1.4.3       System test principles for kernel parts

            When the components of the system have been successfully integrated,
            System Testing have to be performed in accordance with the defined
            test strategy by SchlumbergerSema. System Testing checks both
            functional and non-

APPENDIX 6 - ACCEPTANCE PROCEDURE C.DOC                                        5
(C) 2002 Logica s.r.o.
General-OD template version 1.1

<PAGE>

EuroTel Bratislava - BSCS Migration Study - Migration Study Document
ECF0548:002/Accepted E
2002-01-09

            functional aspects of the system. It checks that the completed unit
            or system provides the specified functions and features, and also
            tests the non-functional aspects such as performance and capacity. A
            dry-run of Factory Acceptance Tests for subcontractors should also
            be included as part of System Test. Records of test runs, progress
            and results are kept. The following principles apply:

            -     Test assemblages for System Testing are constructed from
                  software and hardware which has completed integration testing
                  and is correspondingly under configuration control.

            -     System Tests test for the required functionality to provide
                  confidence that the system complies with the requirements
                  before it enters formal acceptance testing with the customer.

            -     System Tests test for non-functional aspects of the system,
                  e.g. performance, reliability, recovery and availability,
                  portability, efficiency and security and safety where these
                  are appropriate.

            -     Regression tests must be performed to establish confidence in
                  the changes made as a result of error correction. Changes must
                  be undertaken to configuration-controlled units in a
                  systematic and controlled manner.

1.4.4       Aims

            -     To demonstrate that an object satisfies the stated
                  requirements of its functional design and construction
                  criteria.

            -     To confirm that an object is appropriate for its intended
                  purpose and usage

            -     To record the execution and results of the tests conducted.

            -     To provide a definitive and repeatable verification and
                  validation process with deterministic results.

1.4.5       Exit criteria

            -     Verified and validated object placed under configuration
                  control.

            -     Completion of all defined test cases and review of results,
                  (or decision to abandon).

1.4.6       Outputs

            -     Integration and System test plan

            -     Integration and System test specification

            -     Test Results

6                                        APPENDIX 6 - ACCEPTANCE PROCEDURE C.DOC
                                                          (C) 2002 Logica s.r.o.
                                                 General-OD template version 1.1

<PAGE>

EuroTel Bratislava - BSCS Migration Study - Migration Study Document
ECF0548:002/Accepted E
2002-01-09

            -     Test Transmittal Report

            -     Test Log

            -     Test Defect Observation Report

            -     Test Summary Report

1.5         Acceptance Test

            Acceptance is in several stages during the project according the
            plan project. Acceptance is against a Functional Requirements
            Specifications. Functional Requirements Specification given in the
            plan to how we will demonstrate non-functional requirements such as
            reliability. The acceptance criteria should be defined in the
            Acceptance Test Plan. The criteria should be defined in terms, which
            prevent trivial failures from stopping acceptance.

            On occasions, the Acceptance Test Specification is produced by
            SchlumbergerSema, Logica and EuroTel Bratislava a.s. and/or another
            third party. In this case, it is imperative that the document will
            be reviewed against Functional Requirements within the scope of the
            contract.

            Detailed test scripts, called Acceptance Test Descriptions, are
            produced for each test specified in the Acceptance Test
            Specification. These, supported by defined test data, represent the
            detailed instructions used to execute the tests during the
            acceptance process.

            FAT and SAT complete once the defined tests have been executed and
            meet their acceptance criteria.

1.5.1       Aims

            -     To demonstrate that an object satisfies the stated
                  requirements of its functional design and construction
                  criteria.

            -     To confirm that an object is appropriate for its intended
                  purpose and usage

            -     To record the execution and results of the tests conducted.

            -     To provide a definitive and repeatable verification and
                  validation process with deterministic results.

1.5.2       Execution criteria preconditions

            Before start of Acceptation Test cases the Tests described in 1.3.1
            and 1.4 have to be successfully executed.

APPENDIX 6 - ACCEPTANCE PROCEDURE C.DOC                                        7
(C) 2002 Logica s.r.o.
General-OD template version 1.1

<PAGE>

EuroTel Bratislava - BSCS Migration Study -
Migration Study Document ECF0548:002/Accepted D
2002-01-09

1.5.3       Exit criteria

            -     Verified and validated object placed under configuration
                  control.

            -     Completion of all defined unit test cases and review of
                  results, (or decision to abandon).

1.5.4       Outputs

            -     Acceptance test plan

            -     Acceptance test specification

            -     Acceptance test description

            -     Test Results:

            -     Test Log

            -     Test Defect Observation

            -     Test Summary Report

            -     Acceptance Certificate

8                                        APPENDIX 6 - ACCEPTANCE PROCEDURE C.DOC
                                                          (C) 2002 Logica s.r.o.
                                                 General-OD template version 1.1

<PAGE>

Annex No. 5: Authorized persons

1.1   Authorized Persons

      The project team will consist of Logica's local staff as well as staff
      from Logica's Customer Care and Billing International Business Unit (CC&B
      IBU), which is based in Logica's Rotterdam office. The CC&B IBU is
      Logica's center of excellence for telecommunications customer care and
      billing systems.

The table below shows the mapping from Logica's organisation to EuroTel's
organization.

<TABLE>
<CAPTION>
     ==========================================================================================
            Logica Role                 Primary EuroTel Contacts                Reason
     ------------------------------------------------------------------------------------------
<S>                                  <C>                                <C>
     Logica Country Manager          General Manager                    Overall Logica-EuroTel
                                     Jozef Barta                        relationship
     Robert Sandor
     ------------------------------------------------------------------------------------------
     Logica Regional Operations      IT Director                        Project progress and
     Director                                                           client relationship.
     Peter Morvic                    Milan Hain
                                                                        Overall client
                                                                        relationship and
                                                                        additional prospects
     ------------------------------------------------------------------------------------------
     Logica Sales and Commercial     Senior Manager,                    Additional prospects
     Manager                         Procurement & Logistics

     Katarina Machkova               Martin Horvath
     ------------------------------------------------------------------------------------------
     Logica Project Manager          EuroTel Project Manager            Project management
     Juraj Brtko                     Hedvika Eiflerova                  issues
     ------------------------------------------------------------------------------------------
     Logica Technical Manager                                           Technical issues
     Dusan Valasek                   ----------------------------------------------------------
                                                                        Software development
                                                                        issues
     ==========================================================================================
</TABLE>

                                  1/1      Appendix 5 - Authorised persons C.doc<PAGE>

                                                             EXHIBIT 4(b)(ii).52

                                                        [LOGO]EuroTel
                                                        ------------------------
                                                        EuroTel Bratislava, a.s.
                                                        Cislo zmluvy:

--------------------------------------------------------------------------------
                        AGREEMENT ON INTERNATIONAL LEASE
                                  OF PERSONNEL

                     hereinafter referred to as "Agreement"
--------------------------------------------------------------------------------

                                    BETWEEN

     Lessor: T - Mobile International AG, a corporation organized under the laws
          of the Federal Republic of Germany, having its registered office in
          Bonn Kennedy Allee 1-5, 531 75, Bonn, identification no. of the entity
          HRB 008716 ( hereinafter referred to as "T -Mobile")

                                      AND

     Lessee: EuroTel Bratislava, a.s.s., a joint stock company organized under
          the laws of the Slovak Republic, having its registered office at
          Stefanikova 17, Bratislava 811 05, Slovak Republic, Identification No.
          35705019 (hereinafter referred to as "EuroTel")

                    UNDER THE FOLLOWING TERMS AND CONDITIONS

     T - Mobile and EuroTel are hereinafter called the "Party" or collectively
                                 the "Parties".

<PAGE>

AGREEMENT ON INTERNATIONAL LEASE OF PERSONNEL                             Page 2
--------------------------------------------------------------------------------
<TABLE>
<S>          <C>                                                        <C>
Section  1   Lease of Personnel ......................................   3

Section  2   Status and Permits ......................................   4

Section  3   Taxation of Leased Persons ..............................   4

Section  4   Responsibility for the Leased Persons ...................   5

Section  5   Lease Fees ..............................................   5

Section  6   Payment of Lease Fees ...................................   6

Section  7   Duration ................................................   7

Section  8   Confidentiality .........................................   7

Section  9   Disputes ................................................   8

Section  10  Miscellaneous ...........................................   8

Appendix / Individual Order ..........................................  10
</TABLE>

<PAGE>

AGREEMENT ON INTERNATIONAL LEASE OF PERSONNEL                             Page 3
--------------------------------------------------------------------------------

Section 1 Lease of Personnel

     (l) In accordance with the provisions of this Agreement, T-Mobile hereby
     undertakes to provide personnel to EuroTel (hereinafter referred to as the
     "Leased Persons" and or "Experts") for the purpose of execution of
     professional and management services for EuroTel. EuroTel hereby undertakes
     to pay a fee to T-Mobile for the procured lease of Experts. T-Mobile has
     no place of business in the Slovak Republic.

     (2) This Agreement shall be considered to be framework contractual document
     stipulating the terms and conditions of the lease of the Experts to EuroTel
     upon and pursuant to which Parties hereto shall agree upon the engagement
     of the individual Leased Person-Expert.

     (3) Lease of the individual person - Expert shall be effectuated upon the
     due conclusion of the both parts of the Individual Order (SERVICE
     CERTIFICATE AND OFFICIAL REQUEST OF PERSONNEL SERVICE SUPPLY - Part 1 of
     the Individual Order, SERVICE CERTIFICATE AND OFFICIAL CONFIRMATION OF THE
     SELECTED PERSON - Part 2 of the Individual Order). Patterns of such
     Individual Order documents form the Appendix and is enclosed hereto.

     (4) Execution of the Individual Order under this Agreement by virtue of
     which lease of the individual person is to be effectuated shall form and be
     deemed as Individual contractual relationship to which also terms and
     conditions hereof shall apply. Foregoing notwithstanding this Individual
     contractual relationship may be terminated prior to the expiration of the
     term of this Agreement or as the case may be of the term to which the lease
     of the Expert has been agreed upon, (i) by agreement of the Parties, (ii)
     upon termination by one of the Parties without specifying any reason with
     three months notice period, or (iii) as of the lapse of the validity and
     effectivity hereof.

Section 2 Status and Permits

     (1) The Leased Persons, regardless of the title nominated to the individual
     by T-Mobile, shall each remain legal employees of T-Mobile, but EuroTel
     shall define the scope of their duties and supervise their work so that
     EuroTel will be their "economic employer". EuroTel has the right to not
     accept any Leased Person presented by T-Mobile should EuroTel consider the
     Leased Person unable to adequately perform the required tasks.

     (2) EuroTel must obtain the residence and work permits necessary for the
     Leased Persons to live and work in the Slovak Republic in accordance with
     Slovak regulation.

Section 3 Taxation of Leased Persons

     (1) Although the Leased Persons shall not be employed by EuroTel, EuroTel
     agrees to deduct from the lease fee for each Leased Person the amount of
     personal income tax payable to the Slovak Tax Authority on behalf of the
     Leased Person resulting from EuroTel being the economic employer of the

<PAGE>

AGREEMENT ON INTERNATIONAL LEASE OF PERSONNEL                             Page 4
--------------------------------------------------------------------------------

     Leased Person. EuroTel must remit this amount to the Tax Authority on
     behalf of each Leased Person as required by Slovak law. EuroTel shall be
     obliged to make an annual settlement of advance payments of the income tax
     on dependent activity for each Leased Person or in case the Leased Person
     must file and does file a personal income tax return personally, EuroTel
     shall be obliged to issue a confirmation of income recorded on the
     payslips. The tax overpayment arising from the year end reconciliation of
     advance payments of the income tax shall be returned by EuroTel to T-Mobile
     or set off against the lease payments due to T-Mobile for Lease Persons
     pursuant to the terms of this Agreement. Tax arrears arising from the year
     end reconciliation of advance payment of the tax shall be withheld by
     EuroTel from the fee invoiced by T-Mobile.

     (2) Immediately after the end of each calendar year (not later than 5
     January of the following year), EuroTel must issue to T-Mobile and to each
     Leased Person a statement of the amount deducted and remitted as
     prepayments to the Tax Authority on behalf of each Leased Person for the
     preceding calendar year. Until 15 April of the following calendar year
     EuroTel should provide the final amount of personal income tax paid per
     Leased Person to T-Mobile.

     (3) Responsibilities of EuroTel with respect to the tax regime and
     treatment of the leased person as stipulated hereinabove shall apply
     provided that such responsibilities shall be in compliance with the valid
     legal regulation of the Slovak Republic.

Section 4 Responsibility for the Leased Persons

     (1) EuroTel shall be entitled to give work instructions to the Leased
     Persons and to control the quality of the work performed. Leased persons
     who will act as members of the Executive Management Board will report to
     the Board of Directors of EuroTel. T-Mobile shall be responsible and shall
     bear the risk for the results of the work performed by the Leased Persons.
     All technical, office and other equipment necessary so that the Leased
     Persons can perform the work assigned to them shall be provided by EuroTel.

     (2) T-Mobile shall be obliged to advise the Leased Persons of their
     obligation to perform the work with due care and in accordance with their
     best knowledge and capabilities. The Leased Persons shall be obliged to
     comply with Slovak law and with EuroTel's internal regulations, and to
     refrain from any acts contrary to EuroTel's interests.

     (3) Each of the Parties shall be responsible to the other Party for any
     damages incurred as a result of negligence, wilful act, wilful omission
     and/or wilful non-compliance with the obligations arising from this
     Agreement. Indemnification for the damage shall be governed by the
     applicable provisions of the Commercial Code of Germany.

<PAGE>

AGREEMENT ON INTERNATIONAL LEASE OF PERSONNEL                             Page 5
--------------------------------------------------------------------------------

Section 5 Lease Fees

     (1) EuroTel must pay T-Mobile a quarterly lease fee for each Leased Person
     calculated as follows:

          (a)  The gross, monthly salary of the Leased Person under his or her
               contract of employment with T-Mobile (hereinafter referred to as
               "Salary"); and

          (b)  the costs incurred by T-Mobile for the relevant month for the
               benefit of the Leased Person, including (but not limited to)
               housing rental, hotel accommodation, the provision of motor
               vehicles for business or private use and other benefits in kind
               (hereinafter referred to as "Benefits"); and

          (c)  normal business trip expenses incurred by the Leased Person borne
               by EuroTel

          (d)  any costs of Benefits incurred by EuroTel

          (e)  5% of the final amount for Salary under (a) plus Benefits, only
               if provided by T-Mobile under (b). For the purposes of
               calculation of the 5%, the amount of Salary under (a) will be
               included net of the Slovak personal income tax which is to be
               administered and paid by EuroTel and net of all other payments
               provided by EuroTel according to above (b) to (d).

     (2) EuroTel must bear the necessary cost of materials used by the Leased
     Persons in the performance of their work for EuroTel.

     (3) Deviant from section(1), sub. section (b), (c) and (d), EuroTel is also
     permitted to bear any cost occuring with the lease employee, e.g. housing,
     rental, hotel accomodation or other business trip expenses itself. In this
     case these expenses are not reaccounted and paid back to T-Mobile.

Section 6 Payment of Lease Fees

     (1) If EuroTel incurs any costs of Benefits and normal business trip
     expenses, it must inform T-Mobile by the [10/th/] day of each month of
     those costs incurred in the previous month (providing the details
     reasonably required by T-Mobile and specifying the currency of
     expenditure).

     (2) T-Mobile must account for EuroTel's reported costs of Benefits and
     normal business trip expenses as an advance payment against the lease fees
     for the month in which EuroTel incurs the costs. These reported costs,
     borne by EuroTel, will be reported in (Euro). T-Mobile must show any credit
     for advance payment by EuroTel in the relevant invoice. For the avoidance
     of doubt, the amount of the costs of Benefits and normal business trip
     expenses paid by EuroTel shall be set off against the lease fees due in the
     quarter following the payment of these costs.

<PAGE>

AGREEMENT ON INTERNATIONAL LEASE OF PERSONNEL                             Page 6
--------------------------------------------------------------------------------

     (3) By the [15/th/] day of the month following the end of each quarter, T-
     Mobile must deliver to EuroTel an invoice in EURO for the lease fees for
     the previous quarter.

     (4) The payment shall be considered effective on the day when EuroTel gives
     instructions to its nominated bank to process the payment order, assuming
     sufficient funds exist in the bank account from which the payment is
     requested.

Section 7 Duration

     (1) This Agreement shall become effective from the date of the execution of
     this Agreement by both Parties hereto and shall have an initial term until
     December 31, 2003. The Agreement shall automatically be extended by one
     year periods unless terminated by either Party in writing with a three
     months notice period. Such a termination notice shall be delivered to other
     Party not later than three months before lapse of the initial term or as
     the case may be of the extended one-year period.

     (2) Foregoing notwithstanding the contractual relation may be terminated
     prior to the expiration of the term by agreement of the Parties or
     termination by one of the Parties without specifying any reason with three
     months notice period.

Section 8 Confidentiality

     Each Party shall treat confidential information which it obtains from the
     other Party pursuant to the terms of this Agreement confidentially. For the
     purpose of this Agreement confidential information means non-public
     information that became known to other Party hereto or which, under the
     circumstances surrounding disclosure known or ought to be known to the
     other Party ought to be treated as confidential.

Section 9 Disputes

     (1) Any amendment to this Agreement or to any Individual Order shall only
     be effective if agreed by the Parties in writing. Individual Order is
     inseparable part of this Agreement.

     (2) If any provision of this Agreement is held legally invalid now or in
     the future, the validity of the remaining provisions shall not be affected
     thereby. The Parties shall replace any invalid provision with that valid
     provision permitted by law which most closely approximates the original
     intent of the Parties.

     (3) This Agreement shall be governed by, interpreted in compliance with and
     subject to German law.

     (4) Should any disputes or discords arise in the course of this Agreement
     or in connection therewith, such disputes or discords shall be settled, if
     possible, through negotiations between the Parties.

     (5) Should such negotiations fail, all disputes between the Parties arising
     from or in connection with this Agreement shall be decided finally and

<PAGE>

AGREEMENT ON INTERNATIONAL LEASE OF PERSONNEL                             Page 7
--------------------------------------------------------------------------------

     conclusively by the Arbitration Court at the "Bundeskammer der Gewerblichen
     Wirtschaft" in Vienna, Austria, by three arbitrators in accordance with the
     rules of said Court. The language of the proceedings shall be English. The
     cost of the arbitration, including reasonable attorney's fees, incurred by
     the other Party shall be borne by the losing Party. If a Party succeeds
     only partially, the costs are to be borne proportionally to the extent that
     such Party has lost.

Section 10 Miscellaneous

     (1) This Agreement is executed in a Slovak and in English version. If there
     is any discrepancy between the versions, the English version shall prevail.

     (2) The contracting Parties represent that the provisions of this Agreement
     are clear and certain, their contractual freedom is not limited and the
     legal act is made in prescribed form. Each Party represents and warrants
     that the person executing this Agreement on its behalf is fully authorised
     to do so.

/s/ Illegible
-------------                                      -----------------------------
Boon, 2001                                            Bratislava, 9.8.2001
T-Mobile International AG

                                                   /s/ Jozef Barta
                                                   -----------------------------
                                                      Jozef Barta
                                                      CEO/procurator
                                                      EuroTel Bratislava, a.s

                                                   /s/ Jan Pitonak
                                                   -----------------------------
                                                      Jan Pitonak
                                                      General Counsel/procurator
                                                      EuroTel Bratislava, a.s.

                                                      -------------------------
                                                      EuroTel Bratislava, a.s.
                                                      Vajnorska 100/A [GRAPHIC]
                                                      831 03 Bratislava
                                                      -------------------------

<PAGE>

AGREEMENT ON INTERNATIONAL LEASE OF PERSONNEL                             Page 8
--------------------------------------------------------------------------------

                                INDIVIDUAL ORDER

             "SERVICE CERTIFICATE AND OFFICIAL REQUEST OF PERSONNEL
           -----------------------------------------------------------
                   SERVICE SUPPLY (Part 1 of INDIVIDUAL ORDER)

1.   Definition of the position:
-------------------------------

     ---------------------------------------------------------------------------
     ---------------------------------------------------------------------------
     ---------------------------------------------------------------------------
     ---------------------------------

2.   Main duties and responsibilities:
     --------------------------------

     ---------------------------------------------------------------------------
     ---------------------------------------------------------------------------
     ---------------------------------------------------------------------------
     ---------------------------

3.   Timing/Required term of the lease engagement:
-------------------------------------------------

     ---------------------------------------------------------------------------
     --------------------------------------------------

4.   Post positioning within the organization:
     ----------------------------------------

     ---------------------------------------------------------------------------
     ---------------------------------------------------------------------------
     --------------------------------------

--------------------------------------------------------------------------------

Signatures

                                                      Jozef Barta
                                                      CEO/procurator
Representatives of T-Mobile International AG          EuroTel Bratislava, a.s.

              Date                                                  Date
-------------      -------                            -------------      -------

                                                      Jan Pitonak
                                                      General Counsel/procurator
                                                      EuroTel Bratislava, a.s.

                                                                    Date
                                                      -------------      -------

<PAGE>

AGREEMENT ON INTERNATIONAL LEASE OF PERSONNEL                             Page 9
--------------------------------------------------------------------------------

           SERVICE CERTIFICATE AND OFFICIAL CONFIRMATION OF SELECTED
                       PERSON (Part2 of INDIVIDUAL ORDER)

.. Name:
        ------------------------------------------------------------------------

.. Identification number of the employee of T-MOBILE:
                                                     ---------------------------

.. Position at EuroTel:
                       ---------------------------------------------------------

.. Date of birth
                ----------------------------------------------------------------

.. Contact address:
                   -------------------------------------------------------------
                   -------------------------------------------------------------

Timing

       . Beginning:
                    ------------------------------------------------------------

       . Duration:
                    ------------------------------------------------------------

T-Mobile fee
             -------------------------------------------------------------------

Special T-Mobile benefits:
                           -----------------------------------------------------

--------------------------------------------------------------------------------

Signatures

Representatives of, a.s.           Representatives of T-Mobile International AG
EuroTel Bratislava, a.s.

--------------------------                   --------------------------
Jozef Barta
CEO/procurator

--------------------------                   --------------------------
Jon Pitonak
General Counsel/procurator

Date:                                        Date:

--------------------------                   --------------------------

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00036-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00036-of-00352.parquet"}]]