Document:

Solar Development Acquisition and Sale Agreement

 Exhibit 10.1 
 SOLAR DEVELOPMENT ACQUISITION AND SALE AGREEMENT 
 Solar Asset Portfolio

 Dated as of June 7, 2012 
 By and between 
 Solar Power, Inc. 

Buyer 

and 
 Solar
Hub Utilities, LLC 
 Seller 

 LIST OF SCHEDULES 

 

			
	 Schedule 1.1.1
	 	Wire Instructions
		
	 Schedule 6.13
	 	Solar Data
		
	 Schedule 6.14
	 	Permits and Permit Applications to be assigned by Seller at Closing
		
	 Schedule 6.15
	 	Land Contracts to be assigned by Seller at Closing
		
	 Schedule 6.16
	 	Development Documents to be assigned by Seller at Closing

 LIST OF EXHIBITS 

 

			
	 Exhibit A        
	 	Project List
		
	 Exhibit B
	 	Bill of Sale and General Assignment and Assumption Agreement
		
	 Exhibit C
	 	[Reserved]
		
	 Exhibit D
	 	Escrow Agreement
		
	 Exhibit E
	 	Security Agreement
		
	 Exhibit F
	 	[Reserved]

 SOLAR DEVELOPMENT ACQUISITION AND SALE AGREEMENT 

THIS SOLAR DEVELOPMENT ACQUISITION AND SALE AGREEMENT (this “Agreement”) is dated as of June 7, 2012 (the
“Effective Date”) between Solar Power, Inc., a California corporation, hereafter referred to as (“Buyer”) and Solar Hub Utilities, LLC, a Hawaiian Limited Liability company hereafter referred to as
(“Seller”). 
 RECITALS 
 A. Seller has or is in the process of developing, and owns certain rights, interests and assets comprising sixty-eight (68) solar photovoltaic, electricity generating facilities having a total
initial nominal nameplate capacity of 29.2 MWDC (each a “Project” and more than one the “Projects”) on sites in Oahu, Maui and Kona, Hawaii, as further described on the “Project List” attached as
Exhibit A. 
 B. For each Project and in connection therewith Seller has acquired certain real estate rights
and other assets and completed or commenced certain development activities. Pursuant to the terms and conditions of this Agreement, Seller shall be obligated to complete certain Conditions Precedent, Project Milestones and other requirements with
respect to the Projects as a condition to the payment by Buyer to Seller of the Purchase Price for each of the Projects. 
 C.
Buyer desires to acquire all right, title and interest in and to the Acquired Assets comprising the Projects, pursuant to the terms and conditions of this Agreement. 
 D. Seller desires to transfer the Acquired Assets comprising the Projects to Buyer in accordance with the terms hereof. 
 AGREEMENT 
 NOW THEREFORE, for good and valuable consideration, including
the sums to be paid to Seller by Buyer and the covenants and agreements set forth herein, the receipt and sufficiency of which is hereby acknowledged, the Parties agree as follows: 

ARTICLE 1 

DEFINITIONS AND RULES OF INTERPRETATION 
 1.1 Defined Terms. For purposes of this Agreement, the following terms shall have the following meanings, applicable both in the singular and in the plural use of the terms: 

1.1.1 Acquired Assets. All of Seller’s right, title and interest, without reservations or restrictions, in and to all of the
assets and rights comprising the Projects, whether existing now or in the future, including, without limitation, pursuant to or as reflected in any and all Development Documents, Books and Records, Land Contracts, Permits, the Permit Applications,
Reports, Interconnection Rights, Power Purchase Agreements, Project Attributes, Solar Data, or otherwise with respect to any Project. 
 1.1.2 Affiliate. With respect to any Person, any other Person that directly or indirectly, through one or more intermediaries, controls, is controlled by or is under common control with that
Person. The term “control” (including, with correlative meaning, the terms “controlled by” and “under common control with”), as used with respect to any Person, means the possession, directly or indirectly, of the power
to direct or cause the direction of the management and policies of such Person, whether through the ownership of voting securities or partnership interests, by contract or otherwise. 

  
 1 

 1.1.3 Agreement. This Solar Development Acquisition and Sale Agreement, including all
Exhibits and Schedules hereto, as the same may be modified, amended or supplemented from time to time in accordance with Section 12.6. 
 1.1.4 Ancillary Agreements. Any agreement, contract or binding obligation with regard to any Project, whether existing now or in the future, other than Land Contracts, Interconnection Agreements,
and Power Purchase Agreements, including, without limitation, (a) any donation agreement; (b) any PILOT (payment in lieu of taxes) agreement; (c) any road maintenance agreement; (d) any decommissioning agreement; (e) any
transmission easements; (f) access easements, and (g) substation use agreements. 
 1.1.5 Authority. Any
federal, state, local or other governmental, judicial, public or statutory instrumentality, tribunal, agency, authority, body or entity, or any political subdivision thereof having legal jurisdiction over the matter or Person in question.

 1.1.6 Bill of Sale. The term shall have the meaning set forth in Section 3.1.6. 

1.1.7 Books and Records. Any and all data, reports, correspondence, maps, surveys and other business records relating to the
Projects that are generated or obtained by Seller prior to Closing (other than the Solar Data). 
 1.1.8 Business Day.
Any day that is not a Saturday, Sunday or other day on which commercial banks in California or Hawaii are authorized or required by law to remain closed. 
 1.1.9 Buyer Conditions. The term shall have the meaning set forth in Section 2.3.3. 
 1.1.10 Buyer Confidential Information. The term shall have the meaning set forth in Section 8.4.1. 
 1.1.11 Buyer Documents. This Agreement, the General Assignment, the Land Contract Assignment, the Interconnection Rights Assignment, Escrow Agreement, Security Agreement, and each other agreement,
document or instrument to be executed and delivered by Buyer in connection herewith. 
 1.1.12 Buyer Event of Default.
The term shall have the meaning set forth in Section 10.2. 
 1.1.13 Buyer Indemnified Parties. The term
shall have the meaning set forth in Section 9.3.1. 
 1.1.14 Buyer’s Knowledge. The actual and current
knowledge of any of the following Persons: Bradley Ferrell, Steven Kircher and James Pekarsky. 
 1.1.15 Cash Advance. An
advance of the Purchase Price by Buyer to Seller up to an aggregate of Nine Million Dollars ($9,000,000) subject to the terms and conditions set forth in Section 2.2.2. 

1.1.16 Closing. The term shall have the meaning set forth in Section 2.3.1. 

1.1.17 Closing Date. The term shall have the meaning set forth in Section 2.3.1. 

  
 2 

 1.1.18 Code. The Internal Revenue Code of 1986, as the same may be amended from time
to time, including any amendments or any substitute or successor provisions thereto. 
 1.1.19 Conditional Use Permit.
The Conditional Use Permits or equivalent permits issued, or to be issued, whether existing now or in the future, by the various planning or zoning Authorities providing the zoning for and otherwise authorizing the Projects. 

1.1.20 Conditions Precedent. The following conditions with respect to each Project, which collectively comprise one of the
Milestones that Seller must satisfy, at its sole cost and expense, except as set forth in this Agreement, prior to payment by Buyer of the Project Payment for any Project: 
 (a) Notice to Proceed for such Project, including, as appropriate, execution by Buyer of an Interconnection Agreement, with full identification and determination of upgrade costs, and approval of such
upgrade costs pursuant to Section 8.8.2; 
 (b) reasonable written evidence that the Project has qualified for, and
met all conditions precedent other than construction and interconnection, for HECO’s Tier 2 or Tier 3 FIT Program, as applicable, and as in place as of the Closing Date; 
 (c) an executed Lease with the Property owner for such Project, in form and substance approved by Buyer, and with a Title Commitment for such Property in form and content reasonably approved by Buyer, and
at a rent rate consistent with the rent rate set forth in the applicable Land Contract as of the Closing Date; 
 (d) the
Conditional Use Permit, if required by applicable Authorities, for approval of the installation of the Project on the related Property, with approval of the costs of any conditions of approval pursuant to Section 8.8.2; and 

(e) an issued building Permit from the appropriate Authority, allowing for the installation of the Project on the related Property.

 1.1.21 Consents. The term shall have the meaning set forth in Section 8.3. 

1.1.22 Damages. The term shall have the meaning set forth in Section 9.3.1. 

1.1.23 Development Documents. All of the documents and materials with respect to the Projects, including, without limitation, as
defined on Schedule 6.16, whether existing now or in the future. 
 1.1.24 Effective Date. The term shall have the
meaning set forth in the preamble to this Agreement. 
 1.1.25 Encumbrances. Any claim, lien, pledge, mortgage, option,
charge, easement, security interest, right-of-way, judgment, encumbrance, lease, interest, mineral reservation, covenant, conditional sales contract, title retention arrangement or restriction or other estate, grant or right of Seller or any third
parties. 
 1.1.26 Endorsements. ALTA, CLTA or company form endorsements required by Buyer that are available in the
State of Hawaii with respect to the Property. 
 1.1.27 Environmental Laws. All Laws that regulate or relate to
(i) the protection or clean-up of the environment; (ii) the Handling of Hazardous Materials; (iii) the preservation or protection 

  
 3 

 
of waterways, groundwater, drinking water, air, wildlife, plants or other natural resources; and (iv) the health and safety of persons or property, including protection of the health and
safety of employees. Environmental Laws shall include, without limitation, the Resource Conservation & Recovery Act, Clean Water Act, Safe Drinking Water Act, Occupational Safety and Health Act, Toxic Substances Control Act, Clean Air Act,
Comprehensive Environmental Response, Compensation and Liability Act, Emergency Planning and Community Right-to-Know Act, Hazardous Materials Transportation Act, and Centers for Disease Control guidelines, policies and procedures, and all analogous
or related Laws. 
 1.1.28 Escrow Account. The escrow account maintained by the Escrow Holder pursuant to the terms of
the Escrow Agreement. 
 1.1.29 Escrow Agreement. The agreement between Buyer, Seller and Escrow Holder regarding the
holding and disbursement of Cash Advance and Project Payment funds as set forth in Section 2.2, and in the form attached hereto as Exhibit D. 
 1.1.30 Escrow Holder. Title Guaranty Escrow Services, Inc.. 
 1.1.31
Facilities. The solar power generating facilities (including, without limitation, any and all support structures, photovoltaic panels, electrical collection system, access roads, and any and all other equipment, materials and improvements
associated therewith), for an combined nominal nameplate capacity of 29,172,000 watts DC, which are planned for development related to each the Properties in connection with the Project portfolio. 

1.1.32 Formation Documents. The articles or certificate of incorporation or formation and bylaws of a corporation or operating
agreement of a limited liability company. 
 1.1.33 General Assignment. This term shall have the meaning set forth in
Section 3.1.1. 
 1.1.34 Intentionally Deleted. 

1.1.35 Handling. The production, use, treatment, storage, transportation, generation, manufacture, processing, distribution,
disposal, emission, discharge, Release or threatened Release. 
 1.1.36 Hazardous Materials. Any dangerous, hazardous or
toxic substance or constituent or pollutant or contaminant which, pursuant to any Laws in effect as of the Effective Date, has been determined, to be hazardous, toxic or dangerous to human health or the environment, including, but not limited to,
any hazardous substance under the Comprehensive Environmental Response, Compensation and Liability Act, as amended (42 U.S.C.A. § 9601 et. seq.), any solid waste under the Resource Conservation and Recovery Act of 1976, as amended (42 U.S.C.A.
§ 6901 et. seq.), or any contaminant, pollutant, waste or toxic substance under the Clean Air Act, as amended (42 U.S.C.A. § 7401 et. seq.), the Federal Water Pollution Control Act, as amended (33 U.S.C.A. § 1251 et. seq.), the Safe
Drinking Water Act, as amended (42 U.S.C.A. § 300f et. seq.), the Emergency Planning and Community Right-To-Know Act, as amended (42 U.S.C.A sec. 110001 et. seq.), the Occupational Safety and Health Act, as amended (29 U.S.C.A sec. 651 et.
seq.), the Hazardous Materials Transportation Act, as amended, (49 U.S.C.A. sec. 5101 et. seq.) or the Toxic Substances Control Act, as amended (15 U.S.C.A. § 2601 et. seq.), and any equivalent or applicable state or local laws.

 1.1.37 Impairment. With respect to any Project which is impacted by a Seller Event of Default, a cost increase for
such Project over the amount set forth for such Project on the Project Cost Schedule and equal to or greater than $0.28 per watt as a direct result of the applicable Seller Event of Default. 

  
 4 

 1.1.38 Interconnection Agreements. The interconnection agreements, whether existing
now or in the future, with the appropriate Utility for the interconnection of each Project to the Utility distribution grid. 

1.1.39 Interconnection Rights. All rights and interests of the non-Utility party, without reservations or restrictions, in the
Interconnection Agreements. 
 1.1.40 Interconnection Studies. The Interconnection studies and reports identified on
Schedule 6.16. 
 1.1.41 Land Contracts. The letters of intent and Lease Agreements entered into between various
property owners, whether existing now or in the future, including, without limitation, those listed on Schedule 6.15, establishing the tangible real property interests, easements, or leases in the Properties. 

1.1.42 Law. Any law, statute, rule, regulation, ordinance, standard, code, order, judgment, decision, writ, injunction, decree,
certificate of need, award or other governmental restriction, including policy or procedure, issued or enforced by any Authority. 
 1.1.43 Loss. A Loss occurs with respect to a Project if, as a direct result of a Seller Event of Default, (1) such Project no longer qualifies for, or otherwise meets the conditions precedent
for the State of Hawaii’s Tier 2 or 3 FIT Program, (2) the parties determine that such Project cannot achieve Project Milestones 1-5, (3) if Project Milestones 1-5 are or can be achieved, the Project cannot interconnect with the
Utility under the related Interconnection Agreement, or (4) the parties determine by mutual agreement that such Project should not be continued. 
 1.1.44 Material Adverse Effect. Any material adverse change in or effect on any one or more of the Projects or the Acquired Assets that would materially and adversely impact the Buyer under this
Agreement. For purposes of determining whether a Material Adverse Effect exists, the parties shall take into account the underlying business rationale, and the allocation of risk and reward, for the transactions contemplated by this Agreement. For
instance, a circumstance that might otherwise be deemed as material and adverse with respect to a given Project likely will not create a Material Adverse Effect if that Project can be replaced by an Additional Project as allowed herein. Further,
given the fact that, pursuant to Section 10.2.2, no remedy is provided for a Project Default that occurs before the completion of Project Milestones 1-5, a circumstance that might otherwise be deemed as material and adverse likely will
not create a Material Adverse Effect if the material and adverse consequences of that circumstance are of a lesser degree than any possible Project Default that could occur before the completion of Project Milestones 1-5. 

1.1.45 Non-Disclosure Period. The term shall have the meaning set forth in Section 8.6. 

1.1.46 Notice of Completeness. A written or electronic notice from the appropriate Utility or governmental agency(s) that the
application for interconnection with respect to a Project is complete. 
 1.1.47 Notice to Proceed. A “Notice To
Proceed” issued by the applicable Utility with respect to a Project, as contemplated under the State of Hawaii’s Tier 2 or 3 FIT Program. 
 1.1.48 Other Seller Default. The term shall have the meaning set forth in Section 10.2.2. 

  
 5 

 1.1.49 Party or Parties. “Party” means Buyer or Seller individually; and
“Parties” means Buyer and Seller collectively. 
 1.1.50 Permit Applications. Any and all applications,
petitions, filings or requests made to any Authority, whether existing now or in the future, on or before the Closing Date in order to obtain a Permit for the Project. 
 1.1.51 Permits. The licenses, consents, certificates, approvals, and permits required for the construction, installation, ownership or operation of the Projects, whether existing now or in the
future, including, without limitation, as described on Schedule 6.14 of this Agreement, including, without limitation, the Conditional Use Permits, if a Conditional Use Permit is required by Law for the Project. 

1.1.52 Permitted Liens. All of the following: (a) liens for property taxes and installments of assessments and charges of
Authorities not yet due and payable; (b) liens created solely by the act or omission of Buyer; and (c) any other Encumbrances created or permitted with the prior written consent of Buyer or its Representatives. 

1.1.53 Person. Any individual, corporation, partnership, joint venture, association, joint stock company, trust, limited liability
company, decedent’s estate, organization, entity, or unincorporated organization or any Authority. 
 1.1.54 Phase I
Environmental Assessment. Any Phase I Environmental Assessment, if required, in connection with the Projects. 
 1.1.55
Power Purchase Agreement. A power purchase agreement or other evidence of a binding commitment from the applicable Utility for the purchase of the electricity generated by the Facility, whether existing now or in the future, at a rate not
less than $0.238 US per kWh, for a term of not less than twenty (20) years. 
 1.1.56 Program Default. Project
Defaults involving the Loss or Impairment of Projects such that Projects with an aggregate capacity of 12 MW (DC) or less remain. 
 1.1.57 Project Cost Schedule. The estimated aggregate and per Project cost of the Projects as detailed on the schedule to be mutually approved by Buyer and Seller. 

1.1.58 Project Default. With respect to any Project, Loss or Impairment of the Project before completion of Project Milestones 1-5
or Loss or Impairment of the Project before completion of Milestone 6, which in either case is caused by a Seller Event of Default. 
 1.1.59 Project. Any single solar-powered electricity generating plant within the portfolio of Projects. 
 1.1.60 Projects. The complete portfolio of 68 single solar-powered electricity generating plants (including the Facilities and Interconnection) having a combined nominal nameplate capacity of
29,172,000 watts DC to be located on the various Properties, and any Additional Projects added pursuant to Section 5.3. 

1.1.61 Project Attributes. The renewable energy certificates or credits, green tags, emission credits, carbon offsets and any
other environmental attribute currently available or available at any time in the future related to each Property, Facilities or Project, as well as all tax credits, including, without limitation, production tax credits and investment tax credits.

  
 6 

 1.1.62 Project Milestones. The requirements set forth in
Section 2.2.3(a)(1)-(6) that must be satisfied by Seller as a condition to receiving Project Payments for each Project, as further set forth in Section 2.2.3. 

1.1.63 Project Payments. The per Project payment of the Purchase Price as set forth in Section 2.2.3. 

1.1.64 Project Substation. Per the Interconnection Agreement. 

1.1.65 Property. All real property on which any of the Projects is intended to be constructed, as evidenced by Land Contracts,
whether existing now or in the future, including, without limitation, that real property subject to the Land Contracts listed on Schedule 6.15. 
 1.1.66 Purchase Price. The term shall have the meaning set forth in Section 2.2.1. 
 1.1.67 Release. Any spilling, leaking, pumping, pouring, emitting, emptying, discharging, injecting, escaping, leaching, dumping or disposing into the environment or the workplace of any Hazardous
Materials, and otherwise as defined in any Environmental Law. 
 1.1.68 Reports. The Phase I Environmental Assessment,
the Title Commitments, the Interconnection Studies and the Solar Study. 
 1.1.69 Representative. With respect to any
Person, any officer, director, employee of such Person or other Person designated by written notice to act as the Person’s representative. 
 1.1.70 Security Agreement. The security agreement by Buyer in favor of Seller providing Seller a security interest in the Acquired Assets to secure performance by Buyer of the terms of this
Agreement, in the form attached hereto as Exhibit E. 
 1.1.71 Seller. Solar Hub Utilities, LLC, a Hawaii
limited liability company. 
 1.1.72 Seller Conditions. The term shall have the meaning set forth in
Section 2.3.2. 
 1.1.73 Seller Confidential Information. The term shall have the meaning set forth in
Section 8.5.1. 
 1.1.74 Seller Documents. This Agreement, the Bill of Sale, the General Assignment, the Land
Contract/Solar Easement Assignment, the Interconnection Assignment, and each other agreement, document or instrument to be executed and delivered by Seller in connection herewith. 

1.1.75 Seller Expense Schedule. The schedule of expenses to be paid by Seller from the Cash Advance, comprising an Overhead
component and a Project Cost component as more specifically set forth on the budget mutually approved by Buyer and Seller. 

1.1.76 Seller Fee. The term shall have the meaning set forth in Section 2.2.2(a). 

1.1.77 Seller Event of Default. The term shall have the meaning set forth in Section 10.2. 

1.1.78 Seller Indemnified Parties. The term shall have the meaning set forth in Section 9.3.2. 

  
 7 

 1.1.79 Seller’s Knowledge. The actual and current knowledge of the following
Persons: Pat Shudak and Jill Noetzelman. 
 1.1.80 Solar Data. Any and all solar data with regard to the Projects,
whether existing now or in the future, included, or included by reference, on Schedule 6.13 to this Agreement. The Solar Data includes the Solar Study. 
 1.1.81 Survey. A land survey of the Property acceptable to Buyer prepared by a licensed surveyor showing no exceptions that would limit the solar installation on the property. 

1.1.82 Taxes. All federal, state, local, foreign and other net income, gross income, estimated, gross receipts, sales, use, ad
valorem, transfer, franchise, profits, license, lease, service, service use, withholding, payroll, employment, excise, severance, stamp, occupation, premium, property taxes and assessments, windfall profits, value added, commercial rent, customs
duties, capital gain, social security, royalty, documentary or other taxes, fees, assessments, duties or charges of any kind whatever, together with any interest and any penalties, additions to tax or additional amounts with respect thereto, and the
term “Tax” means any one of the foregoing Taxes. 
 1.1.83 Title Commitment. A preliminary commitment from the
Title Company to issue the Title Insurance Policy for the Property insuring the easement, leasehold or fee interests provided under the Land Contracts, as approved by Buyer, and subject only to Permitted Liens, and with such Endorsements as required
by Buyer. 
 1.1.84 Title Company. A title company, qualified and doing business in the State of Hawaii, as selected by
Buyer and reasonably acceptable to Seller. 
 1.1.85 Title Insurance Policy. An ALTA policy of title insurance insuring
Buyer’s interest in the Property, in such amount as Buyer determines, issued by the Title Company, subject only to the Permitted Liens and containing the Endorsements. 
 1.1.86 Utility; Utilities. Hawaiian Electrical Company (HECO), Hawaii Maui Electrical Company (MECO) and Hawaii Electric and Light Company (HELCO), as applicable to each Project. 

1.2 Rules of Interpretation. Unless otherwise expressly provided, or unless required by the context in which any term appears:

 (a) capitalized terms used in this Agreement have the meanings specified in this Article; 

(b) the singular shall include the plural and the plural shall include the singular; 

(c) references to “Articles”, “Sections”, “Schedules” or “Exhibits” (if any) shall be to
articles, sections, schedules or exhibits (if any) of this Agreement; 
 (d) all references to a particular entity shall include
a reference to such entity’s successors and permitted assigns but, if applicable, only if such successors and assigns are permitted by this Agreement; 
 (e) the words “herein”, “hereof’ and “hereunder” shall refer to this Agreement as a whole and not to any particular section or subsection of this Agreement; 

  
 8 

 (f) all accounting terms not specifically defined herein shall be construed in accordance
with generally accepted accounting principles in the United States of America, consistently applied; 
 (g) references to this
Agreement shall include a reference to all schedules and exhibits hereto, as the same may be amended, modified, supplemented or replaced from time to time; 
 (h) references to any agreement, document or instrument shall mean a reference to such agreement, document or instrument as the same may be amended, modified, supplemented or replaced from time to time;

 (i) the use of the word “including” in this Agreement to refer to specific examples shall be construed to mean
“including, without limitation” or “including, but not limited to” and shall not be construed to mean that the examples given are an exclusive list of the topics covered; 

(j) relative to the determination of any period of time, “from” means “including and after”, “to” means
“to, but excluding” and “through” means “through and including”; 
 (k) references to applicable
Laws shall mean a reference to such applicable Laws as the same may be amended, modified, supplemented or restated and be in effect from time to time, including rules and regulations promulgated thereunder; and 

(l) where a Party’s acceptance, approval, consent or concurrence is required in connection with any matter under this Agreement,
such Party shall not unreasonably withhold, condition or delay such acceptance, approval, consent or concurrence. 
 The Parties collectively
have prepared this Agreement, and none of the provisions hereof shall be construed against one Party on the ground that such Party is the author of this Agreement or any part hereof. 

ARTICLE 2 

PURCHASE AND SALE OF ACQUIRED ASSETS 
 2.1 Purchase and Sale of Acquired Assets. 
 2.1.1 Purchase and Sale.
Upon the terms and subject to the conditions set forth in this Agreement, on the Closing Date, Seller shall sell, convey, transfer, assign, and deliver to Buyer, and Buyer shall purchase from Seller, all of the Acquired Assets, which Acquired Assets
shall be sold, conveyed, transferred, assigned and delivered to Buyer for the consideration specified in Section 2.2 below. 
 2.2 Purchase Price; Assumption of Liabilities. 
 2.2.1 Purchase
Price. Buyer agrees to pay to Seller the Purchase Price of One and 50/100 Dollars ($1.50) per Watt DC capacity of each Project, which shall be paid pursuant to the Cash Advance and Project Payment provisions below (the “Purchase
Price”). It is specifically understood and agreed to by the parties that the Closing and the transfer of title to the Acquired Assets shall occur on the Closing Date, but the payment of the Purchas Price shall occur on a post-Closing basis
pursuant to the Cash Advance and Project Payment Provisions below. 

  
 9 

 2.2.2 Cash Advance. 

(a) The Cash Advance shall be used solely (1) for completing the development of the Projects as payment for Overhead and Project
Cost expenses pursuant to the Seller Expense Schedule, such that Seller can satisfy Seller’s Conditions Precedent, Project Milestones and other requirements under this Agreement , (2) for payment of up to Two Million ($2,000,000) of fee to
Seller (the “Seller Fee”) for the retirement of certain debt, and (3) for satisfaction and termination of the Note, defined below, and the loan associated with the Note. Pursuant to that certain Secured Promissory Note dated
April 27, 2012 by and between Buyer and Seller (“Note”), Buyer made a loan to Seller in the amount of One Million Dollars ($1,000,000). The Note was secured by a Security Agreement dated April 27, 2012 encumbering the Acquired
Assets comprising thirteen (13) Projects. Upon the Effective Date, an installment of the Cash Advance in the amount of One Million Dollars ($1,000,000) shall be paid automatically in the form of a credit to repay in full the Note (with Buyer
hereby acknowledging that only principal, and not any interest or fees, is owing on the Note), and upon such payment, (i) the Note, the loan evidenced by the Note, and the Security Agreement securing the Note all shall be terminated,
(ii) the original Note shall be marked as “Paid in Full” and shall be cancelled and returned by Buyer to Seller, and (iii) all collateral for the Note shall be released, with Buyer executing and filing such documents as are
necessary to implement the foregoing termination and release. Additionally, upon the Effective Date, an installment of the Cash Advance in the amount of Two Million Dollars ($2,000,000) shall be paid to Seller pursuant to the wire instructions
attached at Schedule 1.1.1. 
 (b) Buyer shall deposit the remaining portions of the Cash Advance with the Escrow Holder in six
installments, as follows (with all of the following installments coming after the initial installments described in Section 2.2.2(a) above) : (i) Buyer shall deposit the first installment in the amount of One Million Dollars
($1,000,000 within twenty-four (24) hours of the execution of this Agreement, the Escrow Agreement and the establishment of the escrow account with Escrow Holder (at which point the total amount of the outstanding Cash Advance shall be
$4,000,000). (ii) Buyer shall deposit the second installment in the amount of Five Hundred Thousand Dollars ($500,000) during the week of June 18-22, 2012 (at which point the total amount of the outstanding Cash Advance shall be
$4,500,000). (iii) Buyer shall deposit the third installment in the amount of One Million Dollars ($1,000,000) during the week of July 2-6, 2012 (at which point the total amount of the outstanding Cash Advance shall be $5,500,000).
(iv) Buyer shall deposit the fourth installment in the amount of One Million Dollars ($1,000,000) during the week of July 9-13 (at which point the total amount of the outstanding Cash Advance shall be $6,500,000). (v) Buyer shall
deposit the fifth installment in the amount of Two Million Dollars ($2,000,000) during the week of July 23-27, 2012 (at which point the total amount of the outstanding Cash Advance shall be $8,500,000). (vi) Buyer shall deposit the sixth
installment in the amount of Five Hundred Thousand Dollars ($500,000) within seven (7) days after Buyer receives notice from Escrow Holder that the balance remaining in the Escrow Account is less than One Million Dollars ($1,000,000) (at which
point the total amount of the outstanding Cash Advance shall be $9,000,000). The failure by Buyer to make any deposit required hereunder in full shall constitute a default under this Agreement. Notwithstanding the foregoing, once Seller has received
Purchase Price payments, net of amounts credited for previous Cash Advances as described in Section 2.2.2(d) below, in an amount equal to, or greater than, two (2) times the remaining unreleased amount of the Cash Advance;
(x) Buyer’s obligation to make Cash Advance deposits shall terminate; (y) the Escrow Holder shall cease making Cash Advances to Seller from the Escrow Account, and (z) Escrow Holder shall release to Buyer any remaining the
remaining Cash Advance balance held in the Escrow Account. 
 (c) As set forth further in the Escrow Agreement: (i) The
Escrow Holder shall release the Overhead portion of the Cash Advance directly to the Seller upon written request of the Seller; provided that, as of the date of such request, the amount of such request coupled with all prior advances for Overhead
does not exceed the cumulative amount authorized under the Seller Expense Schedule to be released by the Escrow Holder as of such date for Overhead, or such request is consented to in writing by the Buyer. (ii) The Escrow Holder shall pay the
Project Cost portion of the Cash 

  
 10 

 
Advance by check or wire transfer to the appropriate third party payee upon written request of the Seller, such request to be accompanied by appropriate invoices; provided that, as of the date of
any such request, the amount of such request coupled with all prior advances for Project Costs from the same specified line item as the line item for such request does not exceed the cumulative amount authorized under the Seller Expense Schedule to
be released by the Escrow Holder as of such date for Project Costs from the specified line item, or such request is consented to in writing by the Buyer. (iii) Buyer’s consent shall be required for the release and payment by the Escrow
Holder of any payments requested by Seller from the Escrow Account for amounts not covered as provided above or in excess of the amounts set forth in the Seller Expense Schedule. 

(d) Buyer shall defer payment of the Purchase Price and Project Payments on Projects otherwise entitled to a Project Payment under
Section 2.2.3 until July 15, 2012, on which date Buyer shall pay all deferred Project Payments. Notwithstanding the foregoing, the Cash Advance shall be partially creditable against the Purchase Price and any Project Payments due and
payable (i) with respect to the 75% of the Project Payment to be deposited and released pursuant to Sections 2.2.3 (b) and (c), on a Fifty Cents ($0.50) per each dollar basis, such that for each payment of One Dollar ($1.00) of the
Purchase Price and any Project Payment due to the Seller as provided herein, the Buyer shall reduce the cash payment of such One Dollar ($1.00) by Fifty Cents ($0.50) and which shall reduce the Cash Advance balance by Fifty Cents ($0.50), until such
time as the Cash Advance balance is reduced to Zero Dollars ($0), and (ii) with respect to the 25% of the Project Payment to be deposited and released pursuant to Sections 2.2.3 (b) and (d), on a dollar for dollar basis, such that for each
payment of One Dollar ($1.00) of the Purchase Price and any Project Payment due to the Seller as provided herein, the Buyer shall reduce the cash payment of such One Dollar ($1.00) by One Dollar ($1.00) and which shall reduce the Cash Advance
balance by One Dollar ($1.00), until such time as the Cash Advance balance is reduced to Zero Dollars ($0) . For example, if a Project Payment is due to Seller in the amount of One Hundred Thousand Dollars ($100,000) and the Cash Advance balance is
Five Hundred Thousand Dollars ($500,000), then Buyer shall make a deposit for the Project Payment in the amount of Thirty Seven Thousand Five Hundred Dollars ($37,500)[50% of the 75% portion of the Project Payment and 0% of the 25% portion of the
Project Payment], and Sixty Two Thousand Five Hundred Dollars ($62,500)[50% of the 75% portion of the Project Payment and 100% of the 25% portion of the Project Payment] shall be credited to the Project Payment from the Cash Advance, and the Cash
Advance balance shall be reduced to Four Hundred Thirty Seven Thousand Five Hundred Dollars ($437,500), and the foregoing allocation formula shall continue until such time as the Cash Advance balance is reduced to Zero Dollars ($0). 

(e) Notwithstanding the foregoing, Buyer shall not be obligated to make a payment of the Cash Advance under
Section 2.2.2(b), and Seller shall not be entitled to obtain Cash Advance disbursements under Section 2.2.2(c) during any time that Buyer has noticed an Event of Default which has not been cured as provided in
Section 10.2.1. 
 2.2.3 Project Payment. 

(a) The Purchase Price shall be paid on a per Project basis (“Project Payment”), based on the satisfaction by Seller,
at its sole cost and expense, except as set forth in this Agreement, of certain Project Milestones with regard to such Project. The Project Milestone are as follows: 
 (1) Seller’s delivery of the current and existing Development Documents for such Project via a DropBox program; 
 (2) Seller’s delivery of the Notice of Completeness for such Project; 

  
 11 

 (3) Seller’s completion of its Conditions Precedent for such Project; 

(4) Seller obtains the “final” building permit from the relevant building department and Buyer has mobilized for construction;

 (5) (a) there has been no material adverse change in such Project as a result of the actions or inactions of the Seller with
respect to its responsibilities and Seller shall have performed in all material respects all of the agreements and complied in all material respects with all of the covenants required hereby to be performed by it with respect to such Project,
including, without limitation, the satisfaction of the Conditions Precedent and the obligations under Section 8.9 with respect to such Project; (b) the representations and warranties of Seller set forth in Article 6 of this
Agreement shall be true and correct in all material respects as of the date thereof as if made as of such time and (c) such Project has not been terminated by agreement of the parties; 

(6) the earlier of (a) Buyer’s completion of construction and interconnection of such Project with the serving Utility; or
(b), provided that such Project has not been terminated by agreement of the parties or a failure of the Seller to perform its obligations under Milestones 1-5 above, the first annual anniversary of the issuance of NTP for such Project. 

(b) Within seven (7) days after written notice by Seller to Buyer and Escrow Holder asserting satisfaction by Seller of Project
Milestones 1–5, as set forth above, for any Project, which notice shall include reasonable written evidence of the satisfaction of such Project Milestones, Buyer shall confirm Seller’s satisfaction of Project Milestones 1-5 and if
confirmed shall deposit the Project Payment for such Project with Escrow Holder for deposit in the Escrow Account. Notwithstanding the foregoing, the Project Payment shall be subject to the Cash Advance crediting provisions set forth in
Section 2.2.2(d) above. Upon written confirmation from Escrow Holder to Seller that Escrow Holder unconditionally holds the full amount of the applicable Project Payment (subject to the Cash Advance crediting provisions set forth in
Section 2.2.2(d) above) for application in the manner set forth in Section 2.2.3(c) below, Seller shall provide to Escrow Holder a release its security interest under the Security Agreement in the Project and all related Acquired Assets to
the extent that they relate solely to the applicable Project. 
 (c) Upon receipt by Escrow Holder of a release by Seller of
its security interest under the Security Agreement in the Project and all related Acquired Assets that relate solely to the applicable Project, Escrow Holder shall immediately (1) release to Seller seventy-five percent (75%) of the Project
Payment with respect to the Project, and (2) in accordance with the terms of Section 2.2.3(d) below, release or continue to hold, as applicable, the remaining twenty-five percent (25%) of the Project Payment for such Project for
distribution in accordance with the terms of Section 2.2.3(d) of this Agreement. Notwithstanding the foregoing, the Project Payment shall be subject to the Cash Advance crediting provisions set forth in Section 2.2.2(d) above. 

(d) With respect to the payment of the remaining twenty five percent (25%) of the Purchase Price for any applicable Project:

 (i) If there is no Cash Advance balance then outstanding after first accounting for the payment of the seventy five percent
(75%) of the Purchase Price with respect to the Project pursuant to Section 2.2.3(c) above, within seven (7) days after written notice by Seller to Buyer and Escrow Holder asserting satisfaction by Seller of Project Milestone 6, as
set forth above, for any Project, which notice shall include reasonable written evidence of the satisfaction of such Project Milestone, Escrow Holder shall release to Seller the remaining 

  
 12 

 
twenty-five percent (25%) of the Project Payment for such Project. Notwithstanding the foregoing, the Project Payment shall be subject to the Cash Advance crediting provisions set forth in
Section 2.2.2(d) above; or 
 (ii) If there is a Cash Advance balance then outstanding after first accounting for the
payment of the seventy five percent (75%) of the Purchase Price with respect to the Project pursuant to Section 2.2.3(c) above, then Seller shall be paid the lesser of (a) the remaining twenty five percent (25%) of the Purchase
Price or (b) the amount of the Cash Advance balance concurrently with the payment of the seventy five percent (75%) of the Purchase Price with respect to such Project pursuant to Section 2.2.3(c) above, with the payment of such
portion of the Purchase Price pursuant to this Section 2.2.3(d)(ii) entirely in the form of a credit against the Cash Advance balance and which shall reduce the Cash Advance balance by the amount of the credit. If the Cash Advance balance is
completely eliminated pursuant to the preceding sentence prior to payment in full of the entire remaining twenty five percent (25%) of the Purchase Price, then any remaining portion of the Purchase Price shall be paid in the manner provided in
Section 2.2.3(d)(i) above 
 (e) Notwithstanding the foregoing, Buyer shall not be obligated to make a Project Payment
under Section 2.2.3(b), and Seller shall not be entitled to obtain Project Payment disbursements under Section 2.2.3(c) and Section 2.2.3(d) during any time that Buyer has noticed an Event of Default which has not
been cured as provided in Section 10.2.1. 
 2.2.4 Allocation of Purchase Price. The Purchase Price shall
include and be allocated among the Acquired Assets on a per Project basis at One and 50/100 Dollars ($1.50) per Watt DC capacity of each Project. Seller and Buyer and their Affiliates shall report, act, and file all Tax returns, form or
reports (including, but not limited to, IRS Form 8594) in all respects and for all purposes consistent with such allocation. Neither Seller nor Buyer shall take any position (whether in audit, Tax returns, or otherwise or with any Authority) that is
inconsistent with such allocation, unless required to do so by applicable Law. 
 The Purchase Price shall be payable by wire transfer. The
Purchase Price is an aggregate figure for all Acquired Assets and other fees for services outlined and due under this Agreement. 
 2.3 Mechanics of Closing. 
 2.3.1 Closing. The consummation of the
transactions contemplated by this Agreement (the “Closing”) shall take place at the offices of Buyer in Roseville, California, on or before 5 p.m., local time, on June 8, 2012, provided all of the conditions to each
Party’s obligations set forth in Articles 3(A) and 4(A) have been satisfied or waived in writing, or at such other place or time as the Parties may mutually agree. The date and time at which the Closing actually occurs is
hereinafter referred to as the “Closing Date”. 
 2.3.2 Failure to Satisfy All Seller Conditions. The
conditions precedent to Seller’s obligations to consummate the transactions contemplated by this Agreement are set forth in Article 4(A) (“Seller Conditions”). Only Seller has the right to waive any of the Seller
Conditions. If Buyer and Seller are unable, despite their reasonable efforts, to satisfy all of the Seller Conditions, Buyer may (a) terminate the agreement and the transaction shall be null and void; or (b) nonetheless elect to consummate
the transactions contemplated herein. 

  
 13 

 2.3.3 Failure to Satisfy All Buyer Conditions. The conditions precedent to
Buyer’s obligations to consummate the transactions contemplated by this Agreement are set forth in Article 3(A) (“Buyer Conditions”). Only Buyer has the right to waive any of the Buyer Conditions. If Buyer and Seller are
unable, despite their reasonable efforts, to satisfy all of the Buyer Conditions, Buyer may (a) terminate the agreement and the transaction shall be null and void; or (b) nonetheless elect to consummate the transactions contemplated
herein. 
 2.3.4 Closing Process. The Closing shall be by an electronic exchange (i.e., facsimile or electronic mail) of
signatures to the Buyer and Seller Documents and closing deliveries, with a subsequent delivery between Buyer and Seller of the original executed Buyer and Seller Documents and closing deliveries the following business day via Federal Express or
other nationally recognized overnight carrier. 
 2.4 Closing Costs. 

2.4.1 Expenses. Except as otherwise specified herein, each Party hereto shall pay its own legal, accounting, out-of-pocket and
other expenses incident to this Agreement and to any action taken by such Party in preparation, negotiation, execution and performance of this Agreement. The Parties shall split the escrow fees equally. 

2.4.2 Prorations. All property taxes, rent, insurance premiums and other costs and expenses relating to the ownership and
operation of the Land Contracts and the Permits shall be prorated between Seller and Buyer as of the Closing Date, so that Seller pays the prorated amounts for the period of time prior to the Closing Date, and Buyer pays the prorated amounts from
and after the Closing Date. 
 2.4.3 Transfer Taxes. Buyer shall be responsible for paying any transfer taxes and any
sales, use or other taxes imposed by applicable Law by reason of the transfer of the Acquired Assets to Buyer as provided herein and any deficiency, interest, penalty or addition asserted with respect thereto. 

2.4.4 Title Insurance Premium. Buyer, at its election and at its sole cost, shall have the right to obtain title insurance on any
of the Property following Closing. Seller, at no out of pocket cost to Seller, shall cooperate with Buyer in connection with obtaining such insurance in a form reasonably acceptable to Buyer. 

ARTICLE 3 

BUYER’S CONDITIONS PRECEDENT 
 3(A) BUYER’S CONDITIONS PRECEDENT TO THE CLOSING 
 The obligation of
Buyer to purchase the Acquired Assets from Seller shall be subject to fulfillment at or prior to the Closing (unless an earlier date is specified) of each of the following conditions precedent: 

3.1 Deliverables by Seller. Upon the terms and subject to the conditions set forth in this Article 3, on or before the
Closing Date Seller shall deliver, or shall cause to be delivered, to Buyer the following: 
 3.1.1 General Assignment.
Seller shall deliver to Buyer two (2) original counterparts of the Bill of Sale and General Assignment and Assumption Agreement in substantially the form of Exhibit B (the “General Assignment”), each such
counterpart being properly executed by an authorized representative of Seller. The General Assignment shall convey all of Seller’s right, title and interest, without reservations or restrictions, in and to all of the Acquired Assets.

  
 14 

 3.1.2 Intentionally Deleted. 

3.1.3 Certificates. Seller shall furnish Buyer with the following certificates of Seller’s officers: 

(a) A certificate executed by the Manager of Seller, certifying as of the Closing Date (a) a true and correct copy of the action of
Seller authorizing the execution, delivery and performance of this Agreement and the other Seller Documents to be executed by it, and the consummation of the transactions contemplated hereby and thereby; and (b) incumbency of Seller’s
authorized signatory to this Agreement. 
 (b) An affidavit from Seller, stating, under penalty of perjury, Seller’s
United States taxpayer identification number and that Seller is not a foreign person, pursuant to section 1445(b)(2) of the Code and Treasury Regulation 1.1445 2(b)(2)(iii)(B) (or any similar provision of state or other Tax Law). 

3.1.4 Escrow Agreement. Seller shall deliver to Buyer two (2) original counterparts of the Escrow Agreement, each such
counterpart being properly executed by an authorized representative of Seller. 
 3.2 Representations, Warranties and
Covenants of Seller. Seller shall have performed in all material respects all of the agreements and complied in all material respects with all of the covenants required hereby to be performed by it, including those covenants set forth in
Article 5 prior to, on or as of the Closing Date, and the representations and warranties of Seller set forth in Article 6 of this Agreement shall be true and correct in all material respects as of the date hereof and as of the Closing
Date as if made as of such time. 
 3.3 No Injunctions or Prohibitions. No preliminary or permanent injunction or other
order, decree, or ruling issued by an Authority, and no statute, rule, regulation, or executive order promulgated or enacted by an Authority, which restrains, enjoins, prohibits, or otherwise makes illegal the consummation of the transaction
contemplated hereby shall be in effect nor shall there be pending any action or proceeding by or before any Authority challenging the lawfulness of or seeking to prevent any of the transactions contemplated by this Agreement, or seeking monetary or
other relief by reason of the consummation of any of such transactions. 
 3(B) BUYER’S CONDITIONS PRECEDENT TO PAYMENT
OF THE PURCHASE PRICE 
 The obligation of Buyer to pay the Purchase Price (and to provide any necessary authorizations to
Escrow Agent to cause Escrow Agent to pay the Purchase Price) shall be subject to fulfillment at or prior to the applicable payment date for the applicable portion of the Purchase Price (each a “Payment Date”) of each of the
following conditions precedent: 
 3.4 Deliverables by Seller. Upon the terms and subject to the conditions set forth in
this Article 3, on or before the Payment Date, Seller shall deliver, or shall cause to be delivered, to Buyer the following: 
 3.4.1 Consents. Seller shall deliver to Buyer original executed copies of the Consents required for the acquisition, development, ownership, construction, operation and maintenance of the Project
for which a Project Payment is requested and obtained by Seller in accordance with Section 8.3, each in a form reasonably satisfactory to Buyer and irrevocable. 

  
 15 

 3.4.2 Assignment and Further Assurances. Buyer and Seller agree and acknowledge that
certain agreements, rights and interests comprising the Acquired Assets, including under or pursuant to the Development Documents and Land Contracts, may mature or formalize after the Closing Date. Accordingly, prior to payment of the Purchase Price
with respect to any Project, Seller shall deliver to Buyer original executed copies of such additional assignments and other documents as are reasonably requested by Buyer to assign, convey, transfer and confirm to Buyer any right, title and
interest in or to any of the Acquired Assets. Additionally, Seller shall use commercially reasonable efforts to take all action, deliver all documents and to do all things necessary, proper or advisable to consummate and make effective the
transactions contemplated by this Agreement. 
 3.5 Representations, Warranties and Covenants of Seller. Seller shall
have performed in all material respects all of the agreements and complied in all material respects with all of the covenants required hereby to be performed by it, including those covenants set forth in Article 5 prior to, on or as of the
Payment Date, and the representations and warranties of Seller set forth in Article 6 of this Agreement shall be true and correct in all material respects as of the Payment Date as if made as of such time, and all references to Closing Date
shall be deemed to refer to the Payment Date. 
 3.6 No Injunctions or Prohibitions. No preliminary or permanent
injunction or other order, decree, or ruling issued by an Authority, and no statute, rule, regulation, or executive order promulgated or enacted by an Authority, which restrains, enjoins, prohibits, or otherwise makes illegal the consummation
of the transaction contemplated hereby shall be in effect nor shall there be pending any action or proceeding by or before any Authority challenging the lawfulness of or seeking to prevent any of the transactions contemplated by this Agreement, or
seeking monetary or other relief by reason of the consummation of any of such transactions. 
 ARTICLE 4 

SELLER’S CONDITIONS PRECEDENT AND PAYMENT REQUIREMENTS 
 4(A) SELLER’S CONDITIONS PRECEDENT TO THE CLOSING 
 The obligation of
Seller to sell, convey, transfer, assign, and deliver to Buyer all of the Acquired Assets shall be subject to fulfillment at or prior to the Closing of each of the following conditions precedent: 

4.1 Deliverables by Buyer. Upon the terms and subject to the conditions set forth in this Article 4, on or before the
Closing Date, Buyer shall deliver, or shall cause to be delivered to Seller, the following: 
 4.1.1 General Assignment.
Buyer shall deliver to Seller two (2) original counterparts of the General Assignment, each such counterpart being properly executed by an authorized representative of Buyer. 

4.1.2 Land Contract Assignment. Buyer shall deliver to Seller two (2) original counterparts of the Land Contract Assignment,
each such counterpart being properly executed by an authorized representative of Buyer. 
 4.1.3 Consideration. Buyer
shall have delivered to Escrow Agent the initial Cash Advance in accordance with the terms of this Agreement. 

  
 16 

 4.1.4 Certificates. Buyer shall have furnished Seller with a certificate executed by
the Secretary or Assistant Secretary of Buyer, certifying as of the Closing Date (a) a true and correct copy of the corporate action of Buyer authorizing the execution, delivery and performance of this Agreement and the other Buyer Documents to
be executed by Buyer , and the consummation of the transactions contemplated hereby and thereby; and (b) the incumbency of Buyer’s authorized signatory to this Agreement and all of the Buyer Documents,. 

4.1.5 Escrow Agreement. Buyer shall deliver to Seller two (2) original counterparts of the Escrow Agreement, each such
counterpart being properly executed by an authorized representative of Buyer. 
 4.1.6 Security Agreement. Buyer shall
deliver to Seller two (2) original counterparts of the Security Agreement, each such counterpart being properly executed by an authorized representative of Buyer. 
 4.1.7 Intentionally Deleted. 
 4.1.8 Opinion. Buyer shall deliver to
Seller an opinion of counsel with respect to the Security Agreement, opining as to customary matters for a commercial financing transaction, including, without limitation, with respect to Buyer, formation and existence; good standing; power and
authority; due authorization, execution and delivery; no violation of organizational materials, contracts, agreements or applicable laws; no required consent or approval; and enforceability. 

4.2 Representations, Warranties and Covenants of Buyer. Buyer shall have performed in all material respects all of the agreements
and complied in all material respects with all of the covenants required hereby to be performed by it including those covenants set forth in Article 5 prior to, on or as of the Closing Date, and the representations and warranties of Buyer set
forth in Article 7 of this Agreement shall be true and correct in all material respects as of the date hereof and as of the Closing Date as if made as of such time. 
 4(B) SELLER’S REQUIREMENTS TO ENSURE BUYER COMPLIANCE IN PAYMENT OF THE PURCHASE PRICE 
 In connection with the payment of any portion of the Purchase Price, Seller shall have the right to ensure that Buyer performs all Buyer requirements in connection with such payment. In this regard, in
order to ensure Buyer’s compliance with all matters necessary to ensure payment of each portion of the Purchase Price when due, Seller shall have the right to require that Buyer complete and perform all of the following matters and items on or
before the applicable Payment Date in connection with each such payment of Purchase Price: 
 4.3 Deliverables by Buyer.
Upon the terms and subject to the conditions set forth in this Article 4, on or before the Payment Date, Buyer shall deliver, or shall cause to be delivered to Seller, the following: 

4.3.1 Consideration. Buyer shall have delivered to Escrow Agent or to Seller, as applicable, the applicable portion of the
Purchase Price in accordance with the terms of this Agreement. 
 4.4 Representations, Warranties and Covenants of Buyer.
Buyer shall have performed in all material respects all of the agreements and complied in all material respects with all of the covenants required hereby to be performed by it including those covenants set forth in Article 5 prior to, on or
as of the Payment Date, and the representations and warranties of Buyer set forth in Article 7 of this Agreement shall be true and correct in all material respects as of the Payment Date as if made as of such time, and all references to
Closing Date shall be deemed to refer to the Payment Date. 

  
 17 

 ARTICLE 5 
 BUYER’S AND SELLER’S COVENANTS 
 5.1 Actions. Throughout
the period both before and after Closing, each party shall use diligent efforts to timely satisfy all the conditions to Closing and to payment of the Purchase Price applicable to such party. 

5.2 Notification of Completion or Failure of Conditions. Each Party to this Agreement will promptly notify the other Party
whenever it has knowledge that a condition under this Agreement has been satisfied or has not been satisfied within the allotted time; and each Party shall otherwise keep the other Party reasonably apprised with respect to the status of satisfying
the obligations hereunder. E-mail communication will be sufficient for notification under this Section 5.2. 
 5.3
Right to Additional Projects. Seller owns the rights to additional solar photovoltaic electricity generating projects in the State of Hawaii which are currently on the Utility reserve schedule for application to the FIT Tier 2 or 3 program,
but excluding the five (5) MW FIT Tier 3 project known as the “D.R. Horton” Project (each an “Additional Project”). Seller shall offer, and Buyer shall have the exclusive first right to purchase, each Additional
Project that is accepted by the Utility from the reserve schedule to Buyer for inclusion in this Agreement. To propose such additions, from time to time as each Additional Project is accepted by the Utility from the reserve schedule, Seller shall
deliver to Buyer original executed copies of (a) a written notice of intent to add one or more Additional Projects to this Agreement and providing relevant due diligence information regarding such Additional Projects, and (b) two
(2) General Assignment with respect to such Additional Projects. If Buyer elects to accept the Additional Projects, then Buyer shall within ten (10) business days of receipt of the offer materials from Seller countersign and return one
(1) copy of the General Assignment to Seller. From and after the date of such acceptance by Buyer, the Projects under this Agreement shall include any Additional Projects accepted by Buyer pursuant to this process. If Buyer does not accept any
one or more Additional Projects, then (i) Buyer shall return the applicable General Assignment documents to Seller unexecuted and such documents, regardless of whether so returned, shall be null and void, and (ii) Seller shall be free to
pursue each such Additional Project so rejected free and clear of this Agreement and of all rights or claims of Buyer. 
 5.4
Update Schedules. Each of the Parties shall update the Schedules to this Agreement on a periodic basis both before and after the Closing. Each change to any such Schedule shall be identified in any such update and such change must be approved
by the Party receiving the updated Schedule (such approval not to be unreasonably withheld or delayed). 
 ARTICLE 6

 REPRESENTATIONS AND WARRANTIES OF SELLER 
 Seller hereby represents and warrants to Buyer, as of the Closing Date, as follows: 
 6.1 Organization. Seller is a limited liability company duly formed, validly existing and in good standing under the Laws of the State of Hawaii. 

6.2 Authorization. Seller has all requisite power and authority to execute and deliver this Agreement, and each other Seller
Document to be delivered at Closing, to own and convey the Acquired Assets and to perform its obligations hereunder and thereunder. 

  
 18 

 6.3 Organizational Documents. Seller has made available to Buyer true and complete
copies of its certificate of organization from the Secretary of State of Hawaii. Seller’s Formation Documents are in full force and effect. Seller is not in violation of any Law affecting its organization or of its Formation Documents in any
manner that would have an adverse impact on the Acquired Assets, Projects or on the completion of the transactions contemplated by this Agreement. 
 6.4 Right and Title to Acquired Assets. Seller has good, valid, marketable and indefeasible title to all of the Acquired Assets free and clear of all matters other than those that would be
disclosed by title and UCC searches with respect to the Acquired Assets as of the Closing Date. All of the Acquired Assets are in the possession and control of Seller. At Closing, Seller shall have and convey to Buyer all right, title and interest
in and to the Acquired Assets free and clear of all matters other than those that would be disclosed by title and UCC searches with respect to the Acquired Assets as of the Closing Date. None of the matters that would be disclosed by title and UCC
searches with respect to the Acquired Assets as of the Closing Date shall have a Material Adverse Effect on the ability of Buyer to construct the Facilities as contemplated under this Agreement. 

6.5 Authorization and Enforceability. The execution, delivery and performance of this Agreement and the other Seller Documents to
be delivered at Closing and the consummation of the transactions contemplated hereby and thereby by Seller have been duly authorized by all necessary action on the part of Seller. Assuming the due authorization, execution and delivery by
Buyer of this Agreement and the other Seller Documents to which Buyer is a party that are to be delivered at Closing, this Agreement constitutes, and the other Seller Documents to be delivered at Closing when executed and delivered by Seller shall
constitute, legally valid and binding obligations of Seller, enforceable against Seller in accordance with their terms, except as the enforceability thereof may be limited by applicable bankruptcy, insolvency, reorganization, moratorium or similar
Laws affecting the enforcement of creditors’ rights generally and equitable principles. 
 6.6 Violation; Conflicts.
Neither the execution, delivery and performance by Seller of this Agreement or the other Seller Documents to be delivered at Closing nor the transfer of the Acquired Assets and consummation of the transactions contemplated hereby or thereby
(a) violates or conflicts with any provision of Seller’s Formation Documents; (b) breaches, violates, conflicts with or constitutes a default under any Acquired Asset, creates any right of any Person to accelerate, terminate or
cancel, any Acquired Asset; (c) violates the Interconnection Rights, any Laws or any Permits to which Seller or the Acquired Assets are subject; (d) imposes any Encumbrance on any of the Acquired Assets; (e) breaches, violates,
conflicts with or constitutes a default under any of the terms or requirements of, or give any third party the right (with or without notice or lapse of time) to revoke, withdraw, suspend, cancel, terminate or modify, any Permits or Consents to
which the Projects or Acquired Assets are subject; or (f) breaches, violates, conflicts with or constitutes a default under any of the provisions of, or give any third party the right (with or without notice or lapse of time) to declare a
default or exercise any remedy under, or to accelerate any obligation under or cancel, terminate or modify, any written or oral contract, agreement or other obligation to which any of the Acquired Assets, may be bound. 

6.7 Consents and Approvals. Except for Consents to be obtained on or before the Closing Date, no consent, approval or
authorization of, permit from, declaration, filing or registration with, or notice to, any Authority, any third party or any other Person, is required to be made or obtained by Seller in connection with the execution, delivery, performance and
validity of this Agreement and the other Seller Documents to be delivered at Closing, and the consummation of the transactions contemplated hereby and thereby. 
 6.8 Consultants. Except for EN-RGY Concepts, LLC, which was retained by Buyer and to whom Buyer is solely obligated for the payment of any commission or fee, neither Seller nor its Affiliates

  
 19 

 
has, directly or indirectly, engaged the services of any broker, consultant, finder, agent or other intermediary with respect to the transactions contemplated by this Agreement who may be
entitled to any brokerage fee or commission in connection with the transaction referenced herein. 
 6.9 Litigation.
There are no actions, suits or proceedings pending or, to Seller’s Knowledge, threatened, against or affecting any Project or any of the Acquired Assets or Seller’s transfer of rights and consummation of the transactions contemplated
hereby, at law or in equity or before or by any Authority or instrumentality or before any arbitrator of any kind. 
 6.10
Compliance with Law. Seller is in compliance with all Law in all material respects that were or are necessary to the conduct of its business or ownership of the Acquired Assets. Seller has not received any written notification indicating any
violation of, and to Seller’s Knowledge, there is no violation of, or non-compliance with, any Law applicable to the Acquired Assets, the Projects or the transactions contemplated hereby. 

6.11 Tax Matters. Seller has paid all federal, state, and local taxes with respect to the Acquired Assets, Seller’s ownership
or operation of the Acquired Assets. All returns and reports with respect to such taxes that as of the date of this Agreement are required to be filed have been duly and timely filed or an appropriate extension thereof has been obtained. There are
no liens for Taxes on the Acquired Assets, other than for Taxes not yet due and payable as of the Closing Date. To Seller’s Knowledge, there are no pending or threatened proceedings with respect to Taxes relating to Seller or the Acquired
Assets. There are no matters under discussion between Seller and any Authority with respect to Taxes relating to Seller or the Acquired Assets, and no extensions of the statute of limitations have either been requested or granted with respect to
Taxes relating to Seller or the Acquired Assets. 
 6.12 No Other Agreements to Sell the Acquired Assets. Seller has no
legal or other obligation, absolute or contingent, to or with any other Person to sell or affect a sale of all or any portion of the Acquired Assets or to enter into any agreement or cause the entering into of any agreement with respect to the sale
of the Acquired Assets. 
 6.13 Solar Data. Schedule 6.13 to this Agreement is a true and complete list of the
Solar Data in place as of the Closing Date. Seller has delivered to Buyer true and complete copies of all Books and Records containing the Solar Data and any other information listed on Schedule 6.13 in the format identified on said
Schedule 6.13. With respect to each item of Solar Data identified on Schedule 6.13 to this Agreement: 

6.13.1 Seller possesses all right, title, and interest in and to each item of Solar Data and has the right, title, interest and ability
to convey the same to Buyer without reservations or restrictions; 
 6.13.2 the item is not subject to any outstanding
injunction, judgment, order, decree, ruling, or charge; and 
 6.13.3 Seller has not agreed to indemnify any Person for or
against any interference, infringement, misappropriation, or other conflict with respect to the items. 
 6.14 Permits.

 6.14.1 Schedule 6.14 to this Agreement set forth a true and complete list of the licenses, consents, certificates,
approvals, permits and any other authorizations (including the Permits and Permit Applications) by or from any Authority or third party that Seller, to Seller’s Knowledge as of the Closing Date, is, except as expressly noted below, required to
obtain in order to construct, own and operate the Project and the same are in each case assignable without any third party notice, consent or approval. 

  
 20 

 6.14.2 Seller has delivered, or shall deliver at Closing, to Buyer a true and complete copy
of each Permit listed on Schedule 6.14 to this Agreement and obtained by Seller. 
 6.14.3 With respect to each Permit on
Schedule 6.14: 
 (a) such Permit is legal, valid, binding and enforceable in accordance with its terms, and in full
force and effect; 
 (b) no party to such Permit is in non-compliance with the terms and conditions of such Permit, and, to
Seller’s Knowledge, no event has occurred which with notice or lapse of time would constitute non-compliance with such terms and conditions; and 
 (c) no action, suit, proceeding, hearing, investigation, charge, complaint, claim, or demand is pending or, to Seller’s Knowledge, is threatened which challenges the legality, validity, or
enforceability of such Permit. 
 6.15 Land Contracts. 

6.15.1 The Land Contracts comprise all of the Property necessary or appropriate in connection with the successful acquisition,
development, construction, installation, completion, ownership, operation and maintenance of the Project in accordance with all Laws; provided, however, that Buyer acknowledges that some of the Land Contracts are not binding agreements themselves,
but merely letters of intent or similar such documents, and binding agreements for the benefit of Seller with respect to the ownership, leasing, use and/or occupancy of all of the Property do not exist as of Closing. 

6.15.2 Seller has delivered into the DropBox data room true and complete copies of the Land Contracts and with respect thereto:

 (a) each Land Contract is legal, valid, binding and in full force and effect and in each case is assignable without any
third party notice, consent or approval; 
 (b) Seller is not and no other party to any Land Contract is in breach or default,
and to Seller’s Knowledge, no event has occurred which, with notice or lapse of time and without a cure being completed, would constitute a breach or default or permit termination, or modification thereof, or acceleration thereunder; and

 (c) Seller has not, and to Seller’s Knowledge, no other party to any Land Contract has repudiated any provision
thereof. 
 6.15.3 Schedule 6.15 of this Agreement is a true and complete list of all Land Contracts included in the
Acquired Assets. Before Closing, Buyer shall have the right to review and if necessary correct the legal descriptions and APN numbers set forth in Schedule 6.15 so that they conform to the property descriptions in the Title Commitments for
the Property. 
 6.16 Development Documents. Schedule 6.16 contains a true and complete list of all written, oral
or implied contracts, agreements, leases, powers of attorney, guarantees, sureties, arrangements or other commitments in place as of the Closing that are material to the ownership, development or use of the Projects, and other Development Documents
comprising the Acquired Assets. 

  
 21 

 6.16.1 Seller has delivered into the DropBox data room true and complete copies of the
Development Documents and with respect thereto: 
 (a) each Development Document is legal, valid, binding and in full force and
effect and in each case is assignable without any third party notice, consent or approval; 
 (b) Seller is not and no other
party to any Development Document is in breach or default, and to Seller’s Knowledge, no event has occurred which, with notice or lapse of time and without a cure being completed, would constitute a breach or default or permit termination, or
modification thereof, or acceleration thereunder; and 
 6.16.2 Seller has not, and to Seller’s Knowledge, no other party
to any Development Document has repudiated any provision thereof. 
 6.17 Environmental Provisions. 

6.17.1 Other than as set out in any Phase I Environmental Assessment, to Seller’s Knowledge, there has not been a Release of
Hazardous Material on or otherwise affecting any Property that: (i) has imposed any reporting obligations on Seller (or other persons) under any Environmental Law; or (ii) has imposed any obligations on Seller (or other persons) under any
Environmental Law to investigate, assess, monitor, clean-up, contain, remediate, mitigate, remove, store, transport, dispose and/or treat any contamination or prepare or implement any work plans related thereto, or respond to or prepare for any
inquiry, order, hearing or other proceeding by or before any Authority with respect to any contamination. 
 6.17.2 Seller has
not received any written notice of any proceedings, action, or other claim or liability arising under any Environmental Law (including notice of potentially responsible party status under the Comprehensive Environmental Response, Compensation, and
Liability Act, 42 U.S.C. §§ 9601 et. seq. or any state counterpart) from any Person or Authority regarding the Property. 
 6.18 FIT Applications. Seller has submitted and the applicable Utility has accepted a Tier 2 FIT application for each of the Projects. 

6.19 No Debarment. Seller and its Affiliates are not subject to debarment or suspended from participation in procurement programs
under the Federal Acquisition Regulations or any similar procurement regulations of any other Authority. 
 6.20 Foreign
Corrupt Practices Act. No part of the proceeds from the sale of the Acquired Assets hereunder will be used directly or indirectly for any payments to any governmental official or employee, political party, official of a political party,
candidate for political office, or anyone acting in an official capacity, in order to obtain, retain or direct business or obtain any improper advantage, in material violation of the United States Foreign Corrupt Practices Act of 1977, as amended.

 6.21 Schedules; Representations and Warranties. All information contained in the Schedules is true and complete. No
representation or warranty of Seller in this Agreement, or any other document delivered pursuant hereto, or any statement, document, certificate or exhibit furnished by Seller pursuant to this Agreement or in connection with the transactions
contemplated hereby contains any untrue statement of a material fact or omits a material fact necessary to make the statements contained therein not misleading. 

  
 22 

 ARTICLE 7 
 REPRESENTATIONS AND WARRANTIES OF BUYER 
 Buyer hereby represents and
warrants to Seller as follows: 
 7.1 Organization. Buyer shall have the right to form one or more limited liability
companies and to transfer or assign the rights to one or more Projects to such entities, along with the associated Acquired Assets and rights under this Agreement with regard to such Projects. Buyer agrees that all of Buyer’s representations,
warranties, covenants, agreements and obligations hereunder shall apply to each such entity created by Buyer, to the extent of any Projects or Acquired Assets transferred to each such entity. Buyer shall cause each such entity to comply with all of
Buyer’s representations, warranties, covenants, agreements and obligations hereunder. Further, Buyer acknowledges that any such transfer shall be subject to the rights of Seller under the Security Agreement and Buyer shall cause any such
transferee to execute any further documents reasonably requested by Seller to ensure the continuing enforceability and perfection of the security interest granted in the Security Agreement. In the event of any assignment as described above, Buyer
shall not be released of any of its obligations hereunder or under any other documents entered into in connection with or relating to this Agreement, including, but not limited to, the Security Agreement. 

7.2 Authorization. Buyer has all requisite power and authority to execute and deliver this Agreement and each other Buyer Document
and to perform its obligations hereunder and thereunder. The execution, delivery and performance of this Agreement and the other Buyer Documents and the consummation of the transactions contemplated hereby and thereby by Buyer have been duly
authorized by all necessary action on the part of Buyer. Assuming the due authorization, execution and delivery by Seller of this Agreement and the other Buyer Documents to which Seller is a party, this Agreement constitutes, and the other Buyer
Documents when executed and delivered by Buyer shall constitute, the legally valid and binding obligations of Buyer, enforceable against Buyer in accordance with the respective terms thereof, except as the enforceability thereof may be limited by
applicable bankruptcy, insolvency, reorganization, moratorium or similar Laws affecting the enforcement of creditors’ rights generally and equitable principles. 
 7.3 No Conflict or Violation. Neither the execution, delivery and performance by Buyer of this Agreement or the other Buyer Documents nor the transfer of rights and consummation of the transactions
contemplated hereby or thereby (a) violate or conflict with any provision of Buyer’s Corporate Documents or any agreement or contract to which Buyer is a party; or (b) violate any Laws. 

7.4 Consents and Approvals. No consent, approval or authorization of, permit from, declaration, filing or registration with, or
notice to, any Authority, any third party payor or any other Person, is required to be made or obtained by Buyer in connection with the execution, delivery, performance and validity of this Agreement and the other Buyer Documents and the
consummation of the transactions contemplated hereby and thereby. 
 7.5 Consultants. As part of the Project Costs, the
Buyer agrees to compensate its broker, EN-RGY Concepts, with a Project Procurement Fee of $0.05 per watt DC for its participation in the transaction, payable pro rata with the Purchase Price. EN-RGY will certify that it has no other fee arrangement
with the Seller, and will otherwise receive no other compensation from any other party in connection with the Projects and which shall be paid in accordance to the same funding process as defined in Section 2.2.3. 

7.6 Litigation. There are no actions, suits or proceedings pending or, to Buyer’s Knowledge, threatened, affecting the
acquisition of the Acquired Assets by Buyer or the consummation of the transactions contemplated hereby, at law or in equity or before or by any Authority or instrumentality or before any arbitrator of any kind. 

  
 23 

 ARTICLE 8 
 CERTAIN COVENANTS 
 Each of the following covenants are made by Buyer or
Seller, as applicable: 
 8.1 No Breach of Representations and Warranties by Seller. Seller shall not engage in any
practice, take any action, embark on any course of inaction or enter into any transaction or agreement that would violate any provision of this Agreement, any of the other Seller Documents, any of the Development Documents or would cause or result
in any of the representations and warranties set forth in Article 6 to be untrue in any material respect or, after giving effect to any such practice, action, course of inaction, transaction or agreement, which could hinder in any material
respect the transactions contemplated by this Agreement or the other Seller Documents, as applicable. 
 8.2 No Breach of
Representations and Warranties by Buyer. Buyer shall not engage in any practice, take any action, embark on any course of inaction or enter into any transaction or agreement that would violate any provision of this Agreement or any of the other
Buyer Documents or would cause or result in any of the representations and warranties set forth in Article 7 to be untrue in any material respect or, after giving effect to any such practice, action, course of inaction, transaction or
agreement, which could hinder in any material respect the transactions contemplated by this Agreement or the other Buyer Documents. 
 8.3 Consents and Reasonable Efforts. Seller shall take all commercially reasonable steps to obtain all consents, approvals, transfers, permissions, waivers, orders, reissuances and authorizations
of (and make all necessary filings or registrations with) (collectively the “Consents”) all Authorities and other third parties which are required to be obtained or made by them in connection with the consummation of the
transactions contemplated by this Agreement, including, without limitation, for the acquisition, development, construction, installation and completion of the Projects and to effect the various assignments to Buyer as provided in this Agreement.
Buyer, without having to incur third party out of pocket expenses, shall cooperate in good faith with Seller in Seller’s effort to obtain the Consents. 
 8.4 Buyer Confidential Information. 
 8.4.1 Seller acknowledges that Buyer
Confidential Information (as defined below) is valuable and proprietary and Seller agrees not to, directly or indirectly, use, publish, disseminate, describe or otherwise disclose any Buyer Confidential Information without the prior written consent
of Buyer. For purposes of this Agreement, “Buyer Confidential Information” shall mean (i) any and all information provided by Buyer to Seller and identified by Buyer as confidential; and (ii) any and all information
provided by Buyer to Seller with respect to the Projects or the transactions contemplated hereby. Information shall not be deemed to be Buyer Confidential Information if (a) it has become generally known or available within the industry or the
public through no act or omission of Seller; (b) Seller can demonstrate that, prior to disclosure in connection with the transactions contemplated hereby, such information was already in the possession of Seller; (c) it was rightfully
received by Seller from a third party who became aware of it through no act or omission of Seller and who is not under an obligation of confidentiality to Buyer; or (d) Seller can demonstrate it was independently developed by employees or
consultants of Seller. Notwithstanding the foregoing, from and after the Closing, Buyer Confidential Information shall include any information that is an Acquired Asset, whether or not of the type referred to in clauses (b), (c) or
(d) above. 

  
 24 

 8.4.2 Seller shall maintain any Buyer Confidential Information which has been or will be
disclosed directly or indirectly to Seller by or on behalf of Buyer or their Affiliates in confidence and shall not disclose or cause to be disclosed by them or any third person without Buyer’s prior express written consent; provided, however,
that Seller may disclose the Buyer Confidential Information to persons who provide legal, accounting, or other services to Seller in connection with Seller’s evaluation or implementation of the transactions contemplated by this Agreement,
provided that such persons have first been provided with a copy of this Agreement and have been informed of the duties required hereby. 
 8.4.3 Notwithstanding the preceding Section 8.4.1 and Section 8.4.2, Buyer Confidential Information may be disclosed if required by any governmental or regulatory Authority or
court or otherwise by Law; provided, however, that: (i) such Buyer Confidential Information is submitted under any and all applicable provisions for confidential treatment; and (ii) if Seller is permitted to do so, Buyer is given written
notice of the requirement for disclosure promptly after such disclosure is requested, so that it may take whatever action it deems appropriate, including intervention in any proceeding and seeking a protective order or an injunction, to prohibit
such disclosure. 
 8.4.4 Seller agrees that it will not make any use of any Buyer Confidential Information received pursuant to
this Agreement except in connection with the transactions contemplated by this Agreement, unless specifically authorized to do so in writing by Buyer, and this Agreement shall not be construed as a license or authorization to Seller to utilize the
Buyer Confidential Information, except for such purpose. 
 8.4.5 Upon Buyer’s request, Seller shall return to Buyer or
destroy as promptly as practicable, but in a period not to exceed ten (10) days, (a) all Buyer Confidential Information provided to Seller, including, without limitation, all copies of such Buyer Confidential Information; and (b) all
notes or other documents in digital or other format in its possession or in the possession of other persons to whom Buyer Confidential Information was properly provided by Seller. Non-destruction of electronic copies of materials or summaries
containing or reflecting Buyer Confidential Information that are automatically generated through data backup and/or archiving systems and which are not readily accessible by Seller’s business personnel shall not be deemed to violate this
Agreement, so long as the Buyer Confidential Information contained in or reflected in such electronic backup records is not disclosed or used in violation of the other terms of this Agreement. 

8.4.6 Seller acknowledges that a breach of the covenants contained in this Section 8.4 will cause irreparable damage to
Buyer, the exact amount of which will be difficult to ascertain, and that the remedies at law for any such breach will be inadequate. Accordingly, Seller agrees that if Seller breaches any of the covenants contained in this Section 8.4,
in addition to any other remedy that may be available at law or in equity, Buyer shall be entitled to specific performance and injunctive relief, without posting bond or other security and Seller shall have no right or power to raise the defense of
adequate remedy at law. 
 8.5 Seller Confidential Information. 

8.5.1 Buyer acknowledges that Seller Confidential Information (as defined below) is valuable and proprietary to Seller and Buyer agrees
not to, directly or indirectly, use, publish, disseminate, describe or otherwise disclose any Seller Confidential Information without the prior written consent of Seller. For purposes of this Agreement, “Seller Confidential
Information” shall mean (i) any and all information provided by Seller to Buyer and identified by Seller as confidential; and (ii) any and all information provided by Seller to Buyer with respect to the Projects or the
transactions contemplated hereby. Information shall not be deemed to be Seller Confidential Information if (a) the Closing has occurred and such information is also an Acquired Asset under this Agreement; (b) it has become

  
 25 

 
generally known or available within the industry or the public though no act or omission of Buyer; (c) Buyer can demonstrate that, prior to disclosure in connection with the transactions
contemplated hereby, such information was already in the possession of Buyer; (d) it was rightfully received by Buyer from a third party who became aware of it through no act or omission of Buyer and who is not under an obligation of
confidentiality to Seller; or (e) Buyer can demonstrate it was independently developed by employees or consultants of Buyer. 
 8.5.2 Buyer shall maintain any Seller Confidential Information which has been or will be disclosed directly or indirectly to Buyer by or on behalf of Seller in confidence by it and shall not disclose or
cause to be disclosed by Buyer or any third person without Seller’s prior express written consent; provided, however, that Buyer may disclose Seller Confidential Information to persons who provide financial analysis, banking, legal, accounting,
or other services to Buyer in connection with Buyer’s evaluation or implementation of the transactions contemplated by this Agreement, provided that such persons have first been provided with a copy of this Agreement and have been informed of
the duties required hereby. 
 8.5.3 Notwithstanding the preceding Section 8.5.1 and Section 8.5.2,
Seller Confidential Information may be disclosed if required by any governmental or regulatory Authority or court or otherwise by Law or in connection with any proceeding with the Commission; provided, however, that: (i) such Seller
Confidential Information is submitted under any and all applicable provisions for confidential treatment; and (ii) if Buyer is permitted to do so, Seller is given written notice of the requirement for disclosure promptly after such disclosure
is requested, so that it may take whatever action it deems appropriate, including intervention in any proceeding and seeking a protective order or an injunction, to prohibit such disclosure. 

8.5.4 Buyer agrees that it will not make any use of any Seller Confidential Information received pursuant to this Agreement, except in
connection with the transactions contemplated by this Agreement, unless specifically authorized to do so in writing by Seller, and this Agreement shall not be construed as a license or authorization to Buyer to utilize Seller Confidential
Information, except for such purpose. 
 8.5.5 Upon Seller’s request, Buyer shall return or destroy as promptly as
practicable, but in a period not to exceed ten (10) days, (a) all Seller Confidential Information provided to Buyer, including, without limitation, all copies of such Seller Confidential Information; and (b) all notes or other
documents in digital or other format in its possession or in the possession of other persons to whom Seller Confidential Information was properly provided by Buyer. Non-destruction of electronic copies of materials or summaries containing or
reflecting Seller Confidential Information that are automatically generated through data backup and/or archiving systems and which are not readily accessible by a Buyer’s business personnel shall not be deemed to violate this Agreement, so long
as the Seller Confidential Information contained in or reflected in such electronic backup records is not disclosed or used in violation of the other terms of this Agreement. 
 8.5.6 Buyer acknowledges that a breach of the covenants contained in this Section 8.5 will cause irreparable damage to Seller and Seller’s Affiliates, the exact amount of which will be
difficult to ascertain, and that the remedies at law for any such breach will be inadequate. Accordingly, Buyer agrees that if Buyer breaches any of the covenants contained in this Section 8.5, in addition to any other remedy that may be
available at law or in equity, Seller and its Affiliates shall be entitled to specific performance and injunctive relief, without posting bond or other security. 
 8.6 Access to Properties, Information and Employees. Through the Closing Date, Seller will afford to Buyer and its employees and other representatives full and free access to the Acquired Assets

  
 26 

 
and related records during normal working hours in order for Buyer to make such due diligence investigation as it shall determine and to satisfy itself with respect to the conditions precedent
contained in Articles 3 and 4 and compliance with the covenants in Article 5. Buyer shall maintain comprehensive general liability insurance coverage for the activities contemplated by this Section 8.6. Buyer shall
exercise its right of access to the Acquired Assets at its own risk and shall be responsible for, and shall defend and indemnify Seller against, (i) injury or death to any person or damage to any property caused by any negligent act or omission
(including strict liability), or willful misconduct of Buyer, its contractors, agents or employees in the exercise of its access rights; and (ii) liens or other encumbrances arising from Buyer’s activities on the Property under this
Section 8.6. 
 8.7 Confidentiality Regarding this Agreement. The Parties each acknowledge and agree that the
terms of this Agreement shall be considered Seller Confidential Information and Buyer Confidential Information. 
 8.8
Construction of Projects. 
 8.8.1 Buyer Construction of Projects. Subject to the obligations of Seller as
provided in the Conditions Precedent, the Project Milestones and as set forth in Section 8.9 below, Buyer shall have the right to construct the Projects, and to control the manner, means and timing of such construction, at its sole cost
and expense, and in its sole and absolute discretion. Without limiting the generality of the foregoing, Buyer retains the right to purchase all of the panels, inverters, racking, and balance of system components, and subject to the rights of
Environet pursuant to that Right of First Refusal by and between Seller and Environet dated November 2011 with respect to providing certain engineering, procurement and construction services with respect to the Projects, Buyer, retains all rights to
select and negotiate the labor and subcontractors related to the installation and construction of the Projects. 
 8.8.2
Project Cost Increases. If prior to or concurrent with the satisfaction of Project Milestones 1-5 for a Project, Buyer or Seller has determined a cost increase for such Project over the per watt amount set forth for such type of Project on
the applicable Project Cost Schedule and equal to, or greater than $.28 per watt (the “Cost Threshold”), Buyer shall have the right to terminate the construction of such Project by written notice to Seller, unless Seller agrees in
writing to pay, fully and solely from its own account, any additional cost above such Cost Threshold. In the event of a cost increase for a Project over the Cost Threshold where Seller has agreed to bear such cost increase over the Cost Threshold,
such additional cost over the Cost Threshold to be paid by Seller shall be deducted from the Project Payment to be paid pursuant to Section 2.2.3(b), with any additional amount to be paid by Seller to Buyer concurrent with the deadline
for the Project Payment to be paid pursuant to Section 2.2.3(b). 
 8.9 Seller Post-Closing Obligations.
Seller shall, at its sole cost and expense, except as set forth in this Agreement, take all commercially reasonable diligent efforts to complete the Seller’s Conditions Precedent with respect to the Projects, and the satisfaction of the Project
Milestones and otherwise as required in connection with the consummation of the transactions contemplated by this Agreement, including, without limitation, for the acquisition, development, construction, installation and completion of the Project.
From and after Closing, all Land Contracts, Interconnection Agreements, Power Purchase Agreements, Conditional Use Permits, Permits, Permit Applications and all other Development Documents evidencing rights, approvals or assets with respect to the
Projects shall be entered into and obtained in the name of Buyer; provided that, where Seller is required to be identified as the Developer under the FIT applications, Buyer shall be listed as the Project owner. Notwithstanding
the foregoing, Seller shall have no right, power or authority to enter into, modify, amend or supplement any agreement or other binding obligation with respect to any Project, and any documents or materials comprising any such agreement or binding
obligation shall be executed and entered into solely by Buyer, or with the prior written consent of Buyer. With respect to each Project, Seller shall, at its sole cost and 

  
 27 

 
expense, except as set forth in this Agreement, be solely responsible for all costs of such Project until the completion of Project Milestones 1-5 for such Project, as evidenced by the Seller
Expense Schedule. In addition to completing the Seller’s Conditions Precedent with respect to the Projects, and the satisfaction of the Project Milestones, Seller shall further be obligated, at its sole cost and expense, except as set forth in
this Agreement, to obtain and provide to Buyer the following with respect to the Projects: 
 8.9.1 Power Purchase Agreements
with the FIT Program from the Utilities, with a minimum term of twenty (20) years, and at a minimum purchase price of $0.238 US per kWh; 
 8.9.2 All necessary zoning and building applications and resulting permits, including, without limitation, all environmental, land use, building permit, and other approvals, permits, licenses and consents
required from any Authority with respect to the construction, operation and maintenance of the Projects; 
 8.9.3
Interconnection Agreements with transmission studies and interconnection cost upgrades defined, as necessary, for each Project; 

8.9.4 All necessary pre-construction approvals by any Authority, completed and commissioned by the Utility and providing the
“final” sign-off and approval from the applicable building departments; 
 8.9.5 All pre-COD management and
maintenance of communications and relationships with Authorities, opinion leaders, and Property owners, Utilities, and all other third parties with oversight or influence over the Projects or the Acquired Assets and related project management
support; and 
 8.9.6 All non-construction project management personnel needed to complete the Projects. 

8.10 Project Status Reporting and Information. Seller shall weekly conduct a conference call with Buyer or provide a written
status update report to Buyer detailing the status of the Conditions Precedent, Project Milestones, and other requirements of Section 8.9 above, and the projected date that each such requirement will be satisfied for each Project. Seller
shall promptly provide to Buyer for review, comment and approval copies of all documents, drafts, applications, analyses and other materials which are received or sent by Seller during the process of satisfying the Conditions Precedent, Project
Milestones, and other requirements of Section 8.9 above for each Project. 
 8.11 Project Covenant,
Representation and Warranty. Seller hereby covenants and agrees that as of and as a condition to notice of the satisfaction of Project Milestones 1-5 under Section 2.2.3(b) with respect to any Project, the Project shall have all
material rights and approvals necessary to construct and operate the Project, subject to the construction of the Project pursuant to the applicable plans and specifications. 
 8.12 Land Owner Solar Systems. Pursuant to the terms of various Land Contracts, the developer leasing or obtaining easements is obligated to construct photovoltaic solar power systems to be owned
by the landowner as consideration for the real property rights granted thereunder. Seller agrees that it shall be Seller’s obligation at Seller’s sole cost and expense to timely construct such photovoltaic solar power systems in compliance
with the terms and conditions of such Land Contracts. Seller shall provide monthly written reports to Buyer regarding the status of such projects and shall coordinate any such construction with Buyer so as not to interfere with Buyer’s
construction and development of any Projects, 

  
 28 

 8.13 Buyer and Seller Representatives. Each of Buyer and Seller shall appoint a
representative as the single responsible point of contact and sole representative for all matters relating to this Agreement. Buyer’s initial representative shall be James R. Pekarsky and Seller’s initial representative shall be Pat
Shudak. The actions of the appointed representative shall be deemed the acts of the appointing party and shall be fully binding on such party. The Parties shall vest their representatives with sufficient powers to enable them to assume the
obligations and exercise the rights of each Party, as applicable, under this Agreement; provided that, for the avoidance of doubt, neither Owner’s Representative nor Contractor’s Representative shall have the power or authority to waive
any material right or obligation of any Party. Either Party may change its representative by written notice to the other party. 

ARTICLE 9 

ACTIONS BY SELLER AND BUYER AFTER THE CLOSING DATE 
 9.1 Records. Seller and Buyer agree that each will cooperate with and make available to the other Party, during normal business hours after reasonable advance notice, all books and records retained
and remaining in existence after the Closing Date that are necessary in connection with any Tax inquiry, claim, audit, investigation or dispute, any litigation or investigation or any other matter requiring any such books and records or other
assistance. The Party requesting any such books and records shall bear all of the out-of-pocket costs and expenses (including, without limitation, reasonable attorneys’ fees) reasonably incurred in connection with providing such books and
records or other assistance. 
 9.2 Survival. The representations, warranties, covenants and agreements of Buyer and
Seller shall survive until the completion of all of the Projects and the payment of all sums owed by Buyer and Seller under this Agreement. 
 9.3 Indemnifications. 
 9.3.1 By Seller. Subject to the limitation
set forth in Section 9.3.5, from and after the Effective Date, Seller shall indemnify, defend, save and hold harmless Buyer, its Affiliates, and their respective members, managers, shareholders, employees, Representatives, officers,
directors and agents (collectively, the “Buyer Indemnified Parties”) from and against any and all costs, losses, liabilities (including liabilities arising under principles of strict or joint and several liability), damages,
lawsuits, deficiencies, claims and documented out-of-pocket expenses (whether or not arising out of third-party claims) including reasonable attorneys’ fees and all documented out-of-pocket amounts paid in investigation, defense or settlement
of any of the foregoing (collectively, the “Damages”) incurred in connection with or arising out of or resulting from: 
 (i) any breach of any representation, warranty, covenant or agreement made by Seller in this Agreement or any other Seller Document; 

(ii) any other liability, obligation or commitment of any nature (absolute, contingent or otherwise) arising out of the ownership or
operation of the Acquired Assets prior to the completion of Project Milestones 1-5 with respect to each Project (including any liability arising out of Seller’s negligence or intentional act or omission and all obligations to make payments
arising under the Land Contracts until such time); 
 (iii) any liability or obligations of the grantee under the Land
Contracts relating to the period prior to the completion of Project Milestones 1-5 with respect to each Project; 

  
 29 

 (iv) any liability, obligation or commitment of any nature arising out of or related to the
exercise by Seller of Seller’s obligations with respect to the Project Milestones, Conditions Precedent or pursuant to Section 8.9; 
 (v) any liability arising out of Seller’s acts or omissions, including negligence. 
 9.3.2 By Buyer. Subject to the limitation set forth in Section 9.3.5, from and after the Effective Date, Buyer shall indemnify, save and hold harmless Seller, its Affiliates, and their
respective members, managers, shareholders, employees, Representatives, officers, directors and agents (collectively, the “Seller Indemnified Parties”) from and against any and all Damages incurred in connection with or arising out
of or resulting from: 
 (i) any breach of any representation, warranty, covenant or agreement made by Buyer in this Agreement
or any other Buyer Document; or 
 (ii) any other liability, obligation or commitment of any nature (absolute, contingent or
otherwise) arising out of the ownership or operation of the Acquired Assets on or after the completion of Project Milestones 1-5 with respect to each Project (including any liability arising out of Buyer’s negligence or intentional act or
omission and all obligations to make payments arising under the Land Contracts on or after such time); 
 (iii) any liability
or obligations of the grantee under the Land Contracts relating to the period on or after the completion of Project Milestones 1-5 with respect to each Project; 
 (iv) any liability, obligation or commitment of any nature arising out of or related to the exercise by Buyer of Buyer’s obligations with respect to construction in accordance with, or pursuant to,
Section 8.8.1; or 
 (v) any liability arising out of Buyer’s acts or omissions, including negligence.

 9.3.3 Defense of Claims. If any action or proceeding (including any governmental investigation or inquiry) shall be
brought or asserted or threatened to be brought or asserted against an indemnified party in respect of which an indemnity may be sought from an indemnifying party, such indemnified party shall notify the indemnifying party in writing as promptly as
practicable (and in any event within ten (10) Business Days after the service of the citation or summons); provided, however, that the failure of the indemnified party to give timely notice hereunder shall relieve the indemnifying party
of its indemnification obligations hereunder only if, and only to the extent that, such failure caused the Damages for which the indemnifying party is obligated to be greater than they would have been had the indemnified party given timely notice.
The indemnifying party shall have the right to assume the defense of such action or proceeding, including through the retention of counsel reasonably satisfactory to the indemnified party, by notifying the indemnified party within ten
(10) Business Days after receipt of the indemnified party’s written notice. The indemnified party shall have the right to participate in the defense of such action or proceeding at its sole cost and expense; provided, however, that the
indemnifying party shall be liable to the extent provided under this Article 9 for all reasonable costs and expenses of defending such action or proceeding incurred by the indemnified party, including reasonable fees and disbursements of
counsel, if (i) the indemnifying party fails to assume the defense of such action or proceeding in accordance with the preceding sentence; or (ii) the named parties to any such action or proceeding (including any impleaded parties) include
both such indemnified party and the indemnifying party, and such indemnified party shall have been advised by counsel that there may be one or more legal 

  
 30 

 
defenses available to such indemnified party that are different from or additional to those available to the indemnifying party (in which case, if such indemnified party notifies the indemnifying
party in writing that it elects to employ separate counsel at the expense of the indemnifying party, the indemnifying party shall not have the right to assume the defense of such action or proceeding on behalf of such indemnified party). The
indemnifying party shall not be liable for any settlement of any such action or proceeding affected without its written consent (not to be unreasonably withheld). The indemnified party shall not be required to consent to the settlement of any action
or proceeding if such settlement involves anything other than the payment of money by the indemnifying party in full settlement of such action or proceeding. 
 9.3.4 Further Assurances. Each of the Parties hereto shall use commercially reasonable efforts to take all action and to do all things necessary, proper or advisable to consummate and make
effective the transactions contemplated by this Agreement. 
 9.3.5 Limitation on Indemnification. Notwithstanding any
indemnification provision in this Agreement to the contrary, any indemnification obligations of Seller with respect to any Buyer Indemnified Parties provided for in this Agreement and any indemnification obligations of Buyer with respect to any
Seller Indemnified Parties provided for in this Agreement shall in all cases be subject to, and shall be limited by, any express limitations of liability and non-recourse provisions set forth in this Agreement. 

ARTICLE 10 

DEFAULT; TERMINATION; LIMITATIONS ON LIABILITY 
 10.1 Pre-Closing Default. Buyer and Seller agree that in the event that Closing fails to occur, this Agreement shall terminate and neither party shall have any further obligations to the other.

 10.2 Post-Closing Default. 
 10.2.1 Events of Default 
 (a) Seller Default. If (i) Seller
fails to comply timely and in all material respects with any of Seller’s covenants, terms, conditions or obligations contained in this Agreement to be completed or complied with following Closing, upon not less than thirty (30) days’
prior written notice by Buyer to Seller, if such breach or failure is not cured within such 30-day period and, in the case of an Other Seller Default, such breach or failure has a Material Adverse Effect; (ii) any representation or warranty
made by Seller in this Agreement, or any other document furnished by Seller in connection with this Agreement, shall prove to have been false or misleading in any material respect when so made or deemed made and, in the case of an Other Seller
Default, such false or misleading representation or warranty has a Material Adverse Effect, or (iii) an assignment after Closing for the benefit of Seller’s creditors occurs or Seller consents to the appointment of a trustee or receiver or
the filing by or against Seller of any petition or proceeding occurs under any bankruptcy or insolvency law, and in the case of a filing against Seller, such petition or proceeding is not dismissed within sixty (60) days of its initial filing
(each a “Seller Event of Default”). The parties agree that no event, action or circumstance can give rise to or constitute a Seller Event of Default unless that event, action or circumstance also gives rise to or constitutes either
an Other Seller Default, a Project Default or a Program Default. 
 (b) Buyer Default. If (i) Buyer fails to comply
timely and in all material respects with any of Buyer’s covenants, terms, conditions or obligations contained in this Agreement to be completed or complied with following Closing, upon not less than thirty (30) days’ prior written
notice by Seller to Buyer, if such breach or failure is not cured by Buyer within such 30-day period; (ii) any 

  
 31 

 
representation or warranty made by Buyer in this Agreement, or any other document furnished by Buyer in connection with this Agreement, shall prove to have been false or misleading in any
material respect when so made or deemed made, or (iii) an assignment after Closing for the benefit of Buyer’s creditors occurs or Buyer consents to the appointment of a trustee or receiver or the filing by or against Buyer of any petition
or proceeding occurs under any bankruptcy or insolvency law, and in the case of a filing against Seller, such petition or proceeding is not dismissed within sixty (60) days of its initial filing (each a “Buyer Event of
Default”). 
 10.2.2 Rights and Remedies. 

(a) Seller’s Default; Buyer’s Remedies. In the event of a Seller Event of Default, Buyer shall have the following
remedies, as applicable: 
 (1) Non-Project Default and Non-Program Default. In the event of a Seller
Event of Default that is not a Project Default or a Program Default (an “Other Seller Default”), Buyer as its sole and exclusive remedy shall be entitled to shall be entitled to offset against the then unpaid remaining portion of
the Purchase Price any actual damages arising solely and directly from such Other Seller Default ; provided, however, that Buyer only shall be entitled to such an offset once actual damages for all Other Seller Defaults, in the aggregate,
exceed $10,000 (the “Damage Collar”), at which point Buyer shall be able to offset the actual damages over and above the Damage Collar in the manner set forth above. 

(2) Project Default. In the event of a Seller Event of Default that is a Project Default, Buyer shall have the
following remedies, as applicable: 
 (i) For a Project Default that occurs before the satisfaction of Project
Milestones 1-5 in connection with a Project, there shall be no remedy. In such event, Seller may request that Buyer re-assign and transfer the related Project back to Seller, at Buyer’s election and Seller’s expense 

(ii) For a Project Default that occurs after the satisfaction of Project milestones 1-5 but before the satisfaction of
Project Milestone 6, Buyer as its sole and exclusive remedy shall be entitled to an offset (as set forth below) for repayment of any verifiable and non-recoverable out-of-pocket expenses directly incurred in connection with such Project, including
any Project Payment, EPC Costs, or other non-recoverable costs paid or incurred in connection with such Project. Buyer shall have the right to offset such expenses against all Project Payments (for the subject Project or any other Project) currently
held in or subsequently deposited to the Escrow Account. 
 (3) Program Default. In the event of a Seller
Event of Default that is a Program Default, Buyer as its sole and exclusive remedies shall be entitled to (i) notify the Escrow Agent in writing (with a copy to Seller) to cease making Cash Advances as a result of the Program Default,
(ii) instruct the Escrow Agent to return any remaining balance in the Escrow Account to the Buyer, to which Seller will consent, (iii) upon written notice to Seller, to increase Seller’s rate of recovery of the Cash Advance from the
Purchase Price under Section 2.2.2(d) from $0.50 for each 

  
 32 

 
$1.00 of Purchase Price due to Seller for the 75% portion of the Project Payment, up to $1.00 for each $1.00 of Purchase Price for the 75% portion of the Project Payment due to Seller, and
(iv) Seller shall release all remaining Projects and Acquired Assets from, and terminate, the Security Agreement; provided, however, that Seller shall retain any rights asserted against the Security Agreement prior to such termination. In the
event of a Seller Event of Default that is a Program Default, then for all related and underlying Project Defaults where the Project already had satisfied Project Milestones 1-5, but prior to the satisfaction of Project Milestone 6, Buyer shall
additionally be entitled to an offset (as set forth below) for repayment of any verifiable and non-recoverable out-of-pocket expenses directly incurred in connection with such Projects, including any Project Payment, EPC Costs, or other
non-recoverable costs paid or incurred in connection with such Projects. Buyer shall have the right to offset such expenses against all Project Payments (for the subject Project or any other Project) currently held in or subsequently deposited to
the Escrow Account. 
 It is the intent of the parties that in all cases, subject to the terms and limitations set forth above in this
Section 10.2.2(a), that Buyer’s remedies upon a Seller Event of Default shall be limited to Seller’s interest in the Acquired Assets, the Projects and the unfunded portion of the Purchase Price. In no event shall Seller be
personally liable to Buyer for any Seller Event of Default or for reimbursement of any portion of the Purchase Price actually paid to or for the benefit of Seller. 
 (b) Buyer Default; Seller’s Remedies. In the event of a Buyer Event of Default Seller as its sole and exclusive remedies shall be entitled to (i) terminate this Agreement, in which event
Buyer shall cooperate fully and at no additional cost to Seller in effecting the re-conveyance back to Seller (or any nominee of Seller) of all of the Acquired Assets relating to Projects for which the Purchase Price has not been paid or is not
escrowed subject to the terms of this Agreement (and any additions thereto arising after the Closing, and further provided that after Closing, Buyer also shall effect the re-conveyance to Seller in the manner required in this paragraph of any
Projects for which Purchase Price was escrowed at Closing, but was not thereafter paid in full to Seller, as and when required under this Agreement promptly upon the timely failure to pay such sums) pursuant to documentation in form and substance
reasonably satisfactory to Seller; and (ii) without limiting Buyer’s obligation to reconvey the Acquired Assets in the manner set forth in the preceding item (i), foreclose on the Acquired Assets of the Projects that remain subject to the
Security Agreement. Notwithstanding the foregoing, Buyer shall have a right to recover, solely from the Proceeds of the Projects and not from any other assets of Seller, its outstanding Cash Advance balance, provided that such right shall be
unsecured and shall be fully subordinate to Seller’s right to complete or sell the Projects and to recover all of Seller’s costs and expenses for the Projects and all other actual damages incurred by Seller as a result of the Buyer Event
of Default. Notwithstanding the foregoing, (a) Buyer’s right to recover the Seller Fee portion of the Cash Advance shall not be subordinated to Seller’s right to recover costs and expenses for the Projects and (b) with regard to
the subordinated portion of the Cash Advance, Seller shall pay all proceeds from Projects, whether from the completion, ownership, operation, lease, sale, or otherwise (“Proceeds”), after recovery of Seller’s costs and expenses and
actual damages, to Buyer until such time as the outstanding Cash Advance balance has been paid in full. 
 10.2.3 Termination
Events. This Agreement shall terminate: 
 (a) by the mutual written consent of Buyer and Seller;

  
 33 

 (b) by Buyer, upon written notice to Seller of such termination, in the event of an uncured
Seller Event of Default as provided in Section 10.1, an Other Seller Default as provided in Section 10.2.2(a)(1), or a Program Default as provided in Section 10.2.2(a)(3) above; 

(c) by Seller, upon written notice to Buyer of such termination, in the event of an uncured Buyer Event of Default as provided in either
Section 10.1 or 10.2.2(b) above. 
 10.2.4 Effect of Termination. 

(a) In the event of any termination of this Agreement as provided in Section 10.2, this Agreement shall forthwith become
wholly void and of no further force and effect and, except as set forth in this Agreement, there shall be no liability on the part of Buyer or Seller. Notwithstanding the foregoing, no such termination shall serve to release any Party from any
liability (including any such liability under Section 9.3) with respect to any breach of its duties and obligations hereunder prior to such termination, provided that each of the Parties hereto shall use take all action and to do all
things necessary, proper or advisable to consummate and make effective the rights and remedies contemplated by this Agreement. 

(b) Notwithstanding the foregoing, Section 8.4 (Buyer Confidential Information) and Section 8.5 (Seller
Confidential Information) shall survive the termination of this Agreement for a period of one year from the date on which such termination occurs. 
 (c) EXCEPT WITH RESPECT TO THIRD-PARTY CLAIMS, NEITHER PARTY SHALL BE LIABLE FOR ANY LOST OR PROSPECTIVE PROFITS AND IN NO EVENT SHALL EITHER PARTY BE LIABLE FOR ANY OTHER PUNITIVE, EXEMPLARY,
CONSEQUENTIAL, INCIDENTAL OR INDIRECT LOSSES OR DAMAGES (IN TORT, CONTRACT OR OTHERWISE) UNDER OR IN RESPECT TO THIS AGREEMENT OR ANY OTHER BUYER DOCUMENT OR SELLER DOCUMENT OR FOR ANY FAILURE OF PERFORMANCE RELATED HERETO, HOWSOEVER CAUSED.

 ARTICLE 11 
 DISPUTE RESOLUTION 
 11.1 Step Negotiations. The Parties shall
attempt in good faith to resolve all disputes arising out of or relating to this Agreement or any of the transactions contemplated hereby promptly by negotiation, as set forth herein. Either Party may give the other party written notice of any such
dispute not resolved in the normal course of business. Executives of both Parties at levels one level above the Project personnel who have previously been involved in the dispute shall meet at a mutually acceptable time and place within ten
(10) days after delivery of such notice, and thereafter as often as they reasonably deem necessary, to exchange relevant information and to attempt to resolve the dispute. If the matter has not been resolved within thirty (30) days from
the referral of the dispute to such executives, or if no meeting of such executives has taken place within fifteen (15) days after such referral, either Party may initiate mediation as provided herein. If a Party intends to be accompanied at a
meeting by an attorney, the other Party shall be given at least three (3) Business Days’ notice of such intention and may also be accompanied by an attorney. All negotiations pursuant to this clause are confidential and shall be treated as
compromise and settlement negotiations for purposes of the Federal Rules of Evidence and state rules of evidence. Each Party will bear its own costs for this dispute resolution phase. 

11.2 Mediation. In the event that any dispute arising out of or relating to this Agreement or any of the transactions contemplated
hereby is not resolved in accordance with the procedures set forth in Section 11.1, such dispute shall be submitted to a mediator or mediation group that is qualified to mediate 

  
 34 

 
this type of dispute. The mediation shall take place at a mutually agreed upon location in metropolitan San Francisco, California, unless otherwise agreed to by the Parties. If the mediation
process has not resolved the dispute within thirty (30) days of the submission of the matter to mediation or within such longer period as the Parties may agree to, the dispute shall be decided by arbitration as set forth below. Each Party will
bear its own costs for this dispute resolution phase. 
 11.3 Binding Arbitration. All claims, disputes and other matters
in question not resolved by mediation between the Parties to the Agreement arising out of or relating to this Agreement or any of the transactions contemplated hereby shall be decided by binding arbitration by the American Arbitration Association or
by a mutually agreed upon arbitrator. The arbitration shall take place in San Francisco, California and shall be conducted in accordance with the American Arbitration Association Commercial Industry Arbitration Rules then obtaining or a mutually
agreed upon set of arbitration rules. This agreement to arbitrate and any other agreement or consent to arbitrate entered into in accordance herewith will be specifically enforceable under the prevailing arbitration law of any court having
jurisdiction. Notice of demand for arbitration must be filed in writing with the other Party to the Agreement and with the AAA or other mutually agreed to arbitrator. The demand must be made within a reasonable time after the dispute has arisen. In
no event may the demand for arbitration be made if the institution of legal or equitable proceedings based on such dispute is barred by the applicable statute of limitations. If the total dispute, exclusive of interest and arbitration costs, does
not equal or exceed one million dollars, the arbitration shall be heard by one neutral arbitrator. If the total dispute equals or exceeds one million dollars, then the arbitration shall be heard by three neutral arbitrators. Any arbitration may be
consolidated with any other arbitration proceedings. Either Party may join any other interested parties. The award of the arbitrator(s) shall be binding and specifically enforceable in a court of competent jurisdiction. Each Party will bear its own
costs for this dispute resolution phase. 
 ARTICLE 12 

MISCELLANEOUS 
 12.1 Payment Instructions. All amounts under this Agreement which are payable to Seller shall be made by Buyer to Seller by ACH in accordance with the terms of this Agreement, unless alternative
instructions are provided by Seller to Buyer in writing on or before the date for such payment. All amounts under this Agreement which are payable to Buyer shall be made by Seller to Buyer by ACH in accordance with the terms of this Agreement,
unless alternative instructions are provided by Buyer to Seller in writing on or before the date for such payment. 
 12.2
Assignment. Neither Party may assign any of its rights or obligations under this Agreement without the prior written consent of the other Party. Notwithstanding anything to the contrary, the Buyer may assign this Agreement or its rights with
respect to the Acquired Assets comprising any Project to one or more affiliated Special Purpose Entities. 

  
 35 

 12.3 Notices. All notices, requests, demands and other communications which are
required or may be given under this Agreement, including, without limitation, all documents delivered pursuant to this Agreement shall be in writing and shall be deemed to have been duly given when received if personally delivered; when transmitted
if transmitted by telecopy, electronic or digital transmission method; the day after it is sent, if sent for next day delivery to a domestic address by recognized overnight delivery service (e.g., Federal Express or UPS); and upon receipt, if sent
by certified or registered mail, return receipt requested. In each case notice shall be sent to: 
  

													
	If to Seller:	  	Pat Shudak	 		  		  		  		  	
		  	Managing Member	 		  		  		  		  	
		  	Solar Hub Utilities, LLC	 		  		  		  		  	
		  	2937 Kalakaua Avenue #23	 		  		  		  		  	
		  	Honolulu, HI 96815	 		  		  		  		  	
							
		  	Email: pshudak@sehsolar.com	 		  		  		  		  	
							
	with copies to:	  	Quarles & Brady LLP	 		  		  		  		  	
		  	Renaissance Square One	 		  		  		  		  	
		  	Two North Central Avenue	 		  		  		  		  	
		  	Phoenix, Arizona 85004-2391	 		  		  		  		  	
							
		  	Attention: Robert S. Bornhoft	 		  		  		  		  	
		  	Facsimile: (602) 420-5172	 		  		  		  		  	
		  	Telephone: (602) 230-5576	 		  		  		  		  	
		  	Email: bob.bornhoft@quarles.com	 		  		  		  		  	
							
	If to Buyer:	  	Solar Power, Inc.	 		  		  		  		  	
		  	2240 Douglas Blvd., Suite 200	 		  		  		  		  	
		  	Roseville, CA 95661	 		  		  		  		  	
							
		  	Attention: Stephen Kircher	 		  		  		  		  	
		  	Facsimile: (916) 770-8194	 		  		  		  		  	
		  	Telephone: (916) 770-8100	 		  		  		  		  	
		  	Email: skircher@spisolar.com	 		  		  		  		  	
							
	with copies to:	  	Solar Power, Inc,	 		  		  		  		  	
		  	201 California Street, Suite 1250	 		  		  		  		  	
		  	San Francisco, CA 94111	 		  		  		  		  	
							
		  	Attention: Jim Pekarsky	 		  		  		  		  	
		  	Facsimile:	 		  		  		  		  	
		  	Telephone:	 		  		  		  		  	
		  	Email: JPekarsky@spisolar.com	 		  		  		  		  	
							
	and with copies to:	  	Weintraub Genshlea Chediak Tobin & Tobin	 		  		  		  		  	
		  	400 Capitol Mall, Suite 1100	 		  		  		  		  	
		  	Sacramento, CA 95814	 		  		  		  		  	
							
		  	Attention: David C. Adams	 		  		  		  		  	
		  	Facsimile: (916) 446-1611	 		  		  		  		  	
		  	Telephone: (916) 558-6000	 		  		  		  		  	
		  	Email: dadams@weintraub.com	 		  		  		  		  	

 or to such other place and with such other copies as a Party may designate as to itself by written notice to the other
Party. 
 12.4 Choice of Law; Consent to Jurisdiction; Service of Process. 

12.4.1 This Agreement shall be construed, interpreted and the rights of the Parties determined in accordance with the Laws of the State
of California without reference to its choice of law provisions. 

  
 36 

 12.4.2 Subject to Article 11, the Parties hereto hereby irrevocably submit to the
jurisdiction of the federal or state courts of California for any dispute arising out of or relating to this Agreement or any of the transactions contemplated hereby. Each Party hereby irrevocably waives, to the fullest extent permitted by
applicable Law, any objection which it may now or hereafter have to the laying of venue of any such dispute brought in such court or any defense of inconvenient forum. 
 12.4.3 Each of the Parties hereto hereby consents to process being served by the other Party to this Agreement in any arbitration, action or proceeding of the nature specified in Article 11 or
Section 12.4.2 by mailing of a copy thereof in accordance with the provisions of Section 12.3 hereof. 

12.5 Entire Agreement. This Agreement and all exhibits and schedules hereto and any other written agreements entered into in
connection herewith shall constitute the entire understanding of the Parties as to the subject matter hereof and thereof and supersede all prior and contemporaneous agreements, understandings, negotiations, and discussions of the parties, whether
oral or written, and there are no warranties, representations, or other agreements between the parties or on which any of the parties have relied in connection with the subject matter hereof, except as specifically set forth in this Agreement.

 12.6 Amendments and Waivers. No amendment, supplement, modification, waiver, or termination of this Agreement shall be
binding, unless executed in writing by the party to be bound thereby. No waiver of any of the provisions of this Agreement shall be deemed or shall constitute a waiver of any other provision of this Agreement, whether or not similar, nor shall such
waiver constitute a continuing waiver, unless otherwise expressly provided. 
 12.7 Counterparts; Facsimile Signatures.
This Agreement may be executed in counterparts, each of which shall be deemed to be an original, but which together shall constitute a single document. Signatures transmitted by facsimile shall be binding; provided, however, that any person
transmitting his or her signature by facsimile shall promptly send an original signature to the other parties in accordance with Section 12.3. If a facsimile signature is used for purposes of executing this Agreement, then the party
executing by facsimile shall also promptly send an original signature to Escrow Holder. 
 12.8 Expenses. Except as
otherwise specified herein, each Party hereto shall pay its own legal, accounting, out-of-pocket and other expenses incident to this Agreement and to any action taken by such party in preparation for carrying this Agreement into effect. 

12.9 Attorneys’ Fees and Expenses. In the event any of the parties shall commence legal proceedings for the purpose of
enforcing any provision or condition hereof, or by reason of any breach arising under the provisions hereof, then the successful party in such proceeding shall be entitled to court costs and reasonable attorneys’ fees to be determined by the
Court or referee. Without limiting the generality of the foregoing, the prevailing party shall be entitled to recover its attorneys’ fees and other legal expenses incurred in connection with a bankruptcy or other insolvency-related proceeding
of the other party (and including such fees and expenses incurred in efforts, whether successful or not, to obtain adequate protection, annulment, modification or termination of the automatic stay). 

12.10 Invalidity. In the event that any one or more of the provisions contained in this Agreement or in any other instrument
referred to herein (other than a requirement to make payments hereunder), shall, for any reason, be held to be invalid, illegal or unenforceable in any respect, then to the maximum extent permitted by Law, such invalidity, illegality or
unenforceability shall not affect any other provision of this Agreement or any other such instrument. 

  
 37 

 12.11 Legal Representation of the Parties. The parties negotiated this Agreement with
the benefit of legal representation, and any rule of construction or interpretation otherwise requiring this Agreement to be construed or interpreted against any party shall not apply to any construction or interpretation hereof. 

12.12 Titles. The titles, captions or headings of the Articles and Sections herein are inserted for convenience of reference only
and are not intended to be a part of or to affect the meaning or interpretation of this Agreement. 
 12.13 Burden and
Benefit. This Agreement shall be binding upon and shall inure to the benefit of, the Parties hereto and their respective successors and permitted assigns. The Buyer Indemnified Parties and Seller Indemnified Parties shall be third party
beneficiaries of this Agreement and shall be entitled to indemnification, with full rights of enforcement as though each such person was a signatory to this Agreement. Except as provided in this Section, there shall be no third party beneficiaries
of this Agreement. 
 12.14 Cumulative Remedies. Except as otherwise provided in this Agreement to the contrary, all
rights and remedies of either Party hereto are cumulative of each other and of every other right or remedy such Party may otherwise have at law or in equity, and the exercise of one or more rights or remedies shall not prejudice or impair the
concurrent or subsequent exercise of other rights or remedies. 
 12.15 No Partnership or Joint Venture. The Parties
hereto do not intend to create a partnership or joint venture by virtue of this Agreement. No Party shall owe any fiduciary duty to any other Party by virtue of this Agreement or any other Seller Document or Buyer Document or otherwise. 

12.16 No Merger. This Agreement is a fully integrated complete agreement and is not merged with or extinguished by any other
agreement. 
 12.17 Public Announcements. Neither Party may issue any public announcement or other statement with respect
to this Agreement or the transactions contemplated hereby, without the prior consent, which shall not be unreasonably withheld or delayed, of the other Party, unless required by applicable Law, order of a court of competent jurisdiction; provided,
however, that any Party or its Affiliates may make any public disclosure it believes in good faith and upon advice of counsel is required by applicable Law or stock market rule without the consent of (but with notice to) the other Party. 

[SIGNATURE PAGE FOLLOWS] 

  
 38 

 IN WITNESS WHEREOF, the Parties hereto have caused this Agreement to be duly executed on
their respective behalf, by their respective officers thereunto duly authorized, all as of the day and year first above written. 
  

									
	SELLER:	 		 	BUYER:
			
	SOLAR HUB UTILITIES, LLC	 		 	SOLAR POWER, INC.
	  a Hawaii limited liability company	 		 	  a California corporation
					
	By:	 	 /s/ Pat Shudak
	 		 	By:	 	 /s/ Alan M. Lefko

	Name:	 	Pat Shudak	 		 	Name:	 	Alan M. Lefko
	Title:	 	Manager	 		 	Title:	 	Vice President Finance

 [SIGNATURE PAGE TO 
 SOLAR DEVELOPMENT ACQUISITION AND SALE AGREEMENT] 

 SCHEDULE 6.13 

SOLAR DATA 

 Schedule 6.13 
 Solar Reports 
 The Solar Reports, including PV Watts Calculation for each Project, is located in
DropBox. 
 Each PV Watts Calculation is contained within the body of the “Presentation Folder” PDF Document for each Project.

 SCHEDULE 6.14 

LIST OF PERMITS AND PERMIT APPLICATIONS 
 TO BE ASSIGNED AT CLOSING 

																					
	SOLAR HUB UTILITIES	 	HECO-OAHU
	SCHEDULE 6.14	 
	Permits and Permit Applications	 
	APP
NO.	 	SIZE
kW
AC	 	PROJECT
NAME	 	TMK	 	INSTALL ADDRESS	 	CITY	 	ZIP
CODE	 	IBP
APP NO.	 	BUILDING
PERMIT APP NO.	 	BUILDING
PERMIT
NO.	 	PERMIT
ISSUED
	101
1	 	500	 	HARC
CARPORT	 	9-2-001-011	 	94-340
Kunia Rd	 	Waipahu	 	96797	 	2011/IBP09236	 	BPA A2011-
10-0074	 	TBD	 	TBD
	101
2	 	500	 	KVTHC LOT 7	 	9-2-005-023	 	92-1700
Kunia Rd	 	Wahiawa	 	96786	 	2011/IBP09241	 	BPA A2011-
10-0087	 	TBD	 	TBD
	101 3	 	500	 	THURSTON 1	 	6-2-002-003	 	0 Kamehameha Hwy	 	Haleiwa	 	96712	 	2011/IBP09320	 	BPA A2011-
10-0422	 	TBD	 	TBD
	101 4	 	500	 	GINELLA 1-
Kawailoa	 	6-1-005-020	 	62-194
Kawailoa Rd	 	Haleiwa	 	96712	 	2011/IBP09445	 	BPA A2011-
10-0172	 	TBD	 	TBD
	101 9	 	500	 	TROPIC
LAND 010	 	8-7-010-010	 	87-1233
Hakimo Rd	 	Waianae	 	96792	 	2011/IBP09558	 	BPA A2011-
10-0186	 	TBD	 	TBD
	101 13	 	198	 	WONG-
Punaluu	 	5-3-009-093	 	0000
Puhuli St	 	Hauula	 	96717	 	2011/IBP09439	 	BPA A2011-
10-0429	 	TBD	 	TBD
	101 14	 	500	 	TROPIC
LAND 006	 	8-7-010-006	 	87-1239
Hakimo Rd	 	Waianae	 	96792	 	2011/IBP11814	 	BPA A2011-
12-0216	 	TBD	 	TBD
	101 18	 	250	 	965
Kamilonui	 	3-9-019-015	 	965
Kamilonui Place	 	Honolulu	 	96825	 	2011/IBP09433	 	BPA A2011-
12-1223	 	TBD	 	TBD
	101 19	 	500	 	PLATEAU LOOKOUT	 	5-8-002-004	 	58-378
Kam Highway	 	Haleiwa	 	96712	 	2011/IBP11810	 	BPA A2011-
11-1895	 	TBD	 	TBD
	101 28	 	500	 	KAUKONAHUA RIDGE	 	6-5-001-043	 	0000
Kaukonahua Rd	 	Waialua	 	96791	 	2011/IBP12072	 	BPA A2011-
12-1137	 	TBD	 	TBD
	101 31	 	500	 	KULAAUPUNI	 	8-7-003-008	 	87-204 Kulaaupuni St	 	Waianae	 	96792	 	2011/IBP12216	 	BPA A2011-
12-1029	 	TBD	 	TBD
	101 33	 	500	 	KAALA
VIEW	 	6-5-001-033	 	0000
Kaukonahua Rd	 	Waialua	 	96791	 	2011/IBP13143	 	BPA A2011-
12-1310	 	TBD	 	TBD
	101 36	 	500	 	KAALA
LAND	 	6-5-001-010	 	65-670 A Kaukonahua Rd	 	Wahiawa	 	96786	 	2011/IBP13146	 	BPA A2012-
04-2849	 	TBD	 	TBD
	101 95	 	500	 	KUWALE ROAD	 	8-6-007-002	 	86-335
Kuwale Road	 	Waianae	 	96792	 	2011/IBP13141	 	BPA A2012-
04-2847	 	TBD	 	TBD
	101 45	 	260	 	OLOMANA GOLF LINKS	 	4-1-013-010	 	41-1801 Kalanianaole Hwy	 	Waimanalo	 	96795	 	2011/IBP15407	 	BPA A2011-
12-1300	 	TBD	 	TBD
	101 92	 	500	 	WAIANAE VALLEY	 	8-5-004-031	 	85-1330
Waianae Valley Rd	 	Waianae	 	96792	 	2011/IBP13652	 	BPA A2012-
05-0625	 	TBD	 	TBD
	101 49	 	250	 	958
Kamilonui	 	3-9-019-011	 	958
Kamilonui Place	 	Honolulu	 	96825	 	2011/IBP14020	 	BPA A2012-
05-1398	 	TBD	 	TBD
	101 50	 	250	 	968
Kamilonui	 	3-9-019-012	 	968
Kamilonui Place	 	Honolulu	 	96825	 	2011/IBP14021	 	BPA A2012-
05-1393	 	TBD	 	TBD
	101 51	 	250	 	905
Kamilonui	 	3-9-019-021	 	905
Kamilonui Place	 	Honolulu	 	96825	 	2011/IBP14022	 	BPA A2012-
05-1391	 	TBD	 	TBD
	101 52	 	250	 	898
Kamilonui	 	3-9-019-005	 	898
Kamilonui Place	 	Honolulu	 	96825	 	2011/IBP14023	 	BPA A2012-
05-1384	 	TBD	 	TBD
		
	SOLAR HUB UTILITIES	 	HECO-OAHU
	SCHEDULE 6.14	 
	Permits and Permit Applications	 
	APP
NO.	 	SIZE
kW
AC	 	PROJECT
NAME	 	TMK	 	INSTALL ADDRESS	 	CITY	 	ZIP
CODE	 	IBP
APP NO.	 	BUILDING
PERMIT APP NO.	 	BUILDING
PERMIT
NO.	 	PERMIT
ISSUED
	101 53	 	250	 	908
Kamilonui	 	3-9-019-006	 	908
Kamilonui Place	 	Honolulu	 	96825	 	2011/IBP14024	 	BPA A2012-
05-1381	 	TBD	 	TBD
	101 54	 	250	 	948
Kamilonui	 	3-9-019-010	 	948
Kamilonui Place	 	Honolulu	 	96825	 	2011/IBP14025	 	BPA A2012-
05-1373	 	TBD	 	TBD
	101 55	 	250	 	918
Kamilonui	 	3-9-019-007	 	918
Kamilonui Place	 	Honolulu	 	96825	 	2011/IBP14027	 	BPA A2012-
05-1341	 	TBD	 	TBD
	101 56	 	250	 	928
Kamilonui	 	3-9-019-008	 	 928
 Kamilonui Place
	 	Honolulu	 	96825	 	2011/IBP14028	 	BPA A2012-
05-1347	 	TBD	 	TBD
	101 57	 	250	 	978
Kamilonui	 	3-9-019-013	 	 978
 Kamilonui Place
	 	Honolulu	 	96825	 	2011/IBP14029	 	BPA A2012-
05-1399	 	TBD	 	TBD
	101 58	 	250	 	975
Kamilonui	 	3-9-019-014	 	 975
 Kamilonui Place
	 	Honolulu	 	96825	 	2011/IBP14030	 	BPA A2012-
05-1329	 	TBD	 	TBD
	101 59	 	500	 	925
Kamilonui	 	3-9-019-019	 	 925
 Kamilonui Place
	 	Honolulu	 	96825	 	2011/IBP14026	 	BPA A2012-
05-1338	 	TBD	 	TBD
	101 60	 	500	 	895
Kamilonui	 	3-9-019-022	 	 895
 Kamilonui Place
	 	Honolulu	 	96825	 	2011/IBP14019	 	BPA A2012-
05-1288	 	TBD	 	TBD
	101 79	 	500	 	Kipapa	 	9-4-005-052	 	 94-500
 Kam Highway
	 	Mililani	 	96789	 	2011/IBP14232	 	BPA A2012-
05-1204	 	TBD	 	TBD
	101 85	 	500	 	California Av
Lot 1	 	7-5-011-001	 	 1818
 California Avenue
	 	Wahiawa	 	96786	 	2011/IBP14697	 	BPA A2012-
05-1186	 	TBD	 	TBD
	101 87	 	500	 	Peterson
Lot 1	 	9-4-005-010	 	 94-500 C
 Kam Highway
	 	Mililani	 	96789	 	2011/IBP14699	 	BPA A2012-
05-1197	 	TBD	 	TBD
	101 89	 	500	 	Kawiwi 1	 	8-5-034-014	 	 87-1038
 Kawiwi Way
	 	Waianae	 	96792	 	2011/IBP14767	 	BPA A2012-
05-1202	 	TBD	 	TBD
	101 91	 	500	 	Chen Farms	 	8-5-004-019	 	 85-1490 Waianae
 Valley Rd
	 	Waianae	 	96792	 	2011/IBP15118	 	BPA A2012-
05-0644	 	TBD	 	TBD
	101 97	 	500	 	Kamilonui
945	 	3-9-019-017	 	 945
 Kamilonui Place
	 	Honolulu	 	96825	 	2011/IBP15232	 	BPA A2012-
05-1350	 	TBD	 	TBD
	101 98	 	500	 	Kamilonui
955	 	3-9-019-016	 	 955
 Kamilonui Place
	 	Honolulu	 	96825	 	2011/IBP15231	 	BPA A2012-
05-1356	 	TBD	 	TBD
	101 99	 	500	 	Kamilonui
915	 	3-9-019-020	 	 915
 Kamilonui Place
	 	Honolulu	 	96825	 	2011/IBP15228	 	BPA A2012-
05-1354	 	TBD	 	TBD
	101 100	 	500	 	Kamilonui
855	 	3-9-019-024	 	 855
 Kamilonui Place
	 	Honolulu	 	96825	 	2011/IBP15229	 	BPA A2012-
05-1334	 	TBD	 	TBD
	101 101	 	500	 	Kamilonui
865	 	3-9-019-023	 	 865
 Kamilonui Place
	 	Honolulu	 	96825	 	2011/IBP15227	 	BPA A2012-
05-1343	 	TBD	 	TBD
	101 102	 	500	 	Costa	 	8-6-005-008	 	86-344 A
Kuwale Road	 	Waianae	 	96792	 	2011/IBP15221	 	BPA A2012-
05-0640	 	TBD	 	TBD
	101 103	 	500	 	Hawaii Kai	 	3-9-019-025	 	 7460
 Hawaii Kai Dr
	 	Honolulu	 	96825	 	2011/IBP15536	 	BPA A2012-
05-1365	 	TBD	 	TBD

																					
	 SOLAR HUB UTILITIES

SCHEDULE 6.14

Permits and Permit Applications
	  	HELCO-BIG ISLAND (KONA)
											
	APP
NO.	  	SIZE
kW
AC	  	PROJECT
NAME	  	TMK	  	INSTALL
ADDRESS	  	CITY	  	ZIP
CODE	  	To SEARCH
for PERMIT,
USE TMK	  	BUILDING
PERMIT
APP NO.	  	BUILDING
PERMIT
NO.	  	PERMIT
ISSUED
	 50

18
	  	250	  	Kona 1	  	9-2-190-061	  	Maikai Blvd	  	Ocean View	  	96704	  	9-2-190-061	  	B2011-3983K	  	B2012-0138K	  	2/13/2012
	 50

19
	  	250	  	Kona 2	  	9-2-191-047	  	Maikai Blvd	  	Ocean View	  	96704	  	9-2-191-047	  	B2011-3992K	  	B2012-0128K	  	2/10/2012
	 50

20
	  	250	  	Kona 3	  	9-2-187-018	  	Kahili Blvd	  	Ocean View	  	96704	  	9-2-187-018	  	B2011-3991K	  	B2012-0154K	  	2/15/2012
	 50

21
	  	250	  	Kona 4	  	9-2-188-020	  	Lanikai Drive	  	Ocean View	  	96704	  	9-2-188-020	  	B2011-3990K	  	B2012-0386K	  	4/18/2012
	 50

22
	  	250	  	Kona 5	  	9-2-191-034	  	Alii Blvd	  	Ocean View	  	96704	  	9-2-191-034	  	B2011-3989K	  	B2012-0150K	  	2/15/2012
	 50

23
	  	250	  	Kona 6	  	9-2-186-038	  	Kahili Blvd	  	Ocean View	  	96704	  	9-2-186-038	  	B2011-3988K	  	B2012-0152K	  	2/15/2012
	 50

24
	  	250	  	Kona 7	  	9-2-193-049	  	Kona Kai Blvd	  	Ocean View	  	96704	  	9-2-193-049	  	B2011-3987K	  	B2012-0153K	  	2/15/2012
	 50

25
	  	250	  	Kona 8	  	9-2-192-024	  	Alii Blvd	  	Ocean View	  	96704	  	9-2-192-024	  	B2011-3986K	  	B2012-0137K	  	2/13/2012
	 50

26
	  	250	  	Kona 9	  	9-2-189-096	  	Maile Drive	  	Ocean View	  	96704	  	9-2-189-096	  	B2011-3985K	  	B2012-0136K	  	2/13/2012
	 50

27
	  	250	  	Kona 10	  	9-2-187-034	  	Kahili Blvd	  	Ocean View	  	96704	  	9-2-187-034	  	N/A	  	B2012-0149K	  	2/15/2012
	 50

28
	  	250	  	Kona 11	  	9-2-185-084	  	Prince Kuhio Blvd	  	Ocean View	  	96704	  	9-2-185-084	  	N/A	  	B2012-0161K	  	2/16/2012
	 50

29
	  	250	  	Kona 12	  	9-2-185-051	  	Maile Drive	  	Ocean View	  	96704	  	9-2-185-051	  	N/A	  	B2012-0162K	  	2/16/2012
	 50

30
	  	250	  	Kona 13	  	9-2-189-047	  	Maile Drive	  	Ocean View	  	96704	  	9-2-189-047	  	N/A	  	B2012-0134K	  	2/13/2012
	 50

31
	  	250	  	Kona 14	  	9-2-185-071	  	Macadamia Dr	  	Ocean View	  	96704	  	9-2-185-071	  	N/A	  	B2012-0388K	  	4/18/2012
	 50

32
	  	250	  	Kona 15	  	9-2-192-012	  	Alii Blvd	  	Ocean View	  	96704	  	9-2-192-012	  	N/A	  	B2012-0135K	  	2/13/2012
	 50

33
	  	250	  	Kona 16	  	9-2-189-060	  	Maikai Blvd	  	Ocean View	  	96704	  	9-2-189-060	  	N/A	  	B2012-0151K	  	2/15/2012
	 50

34
	  	250	  	Kona 17	  	9-2-185-037	  	Kahili	  	Ocean View	  	96704	  	9-2-185-037	  	N/A	  	B2012-0387K	  	4/18/2012
	 50

35
	  	250	  	Kona 18	  	9-2-190-059	  	Maikai Blvd	  	Ocean View	  	96704	  	9-2-190-059	  	N/A	  	B2012-0126K	  	2/10/2012
	 50

36
	  	250	  	Kona 19	  	9-2-190-010	  	Alii	  	Ocean View	  	96704	  	9-2-190-010	  	N/A	  	B2012-0125K	  	2/10/2012
	 50

37
	  	250	  	Kona 20	  	9-2-191-048	  	Poha Drive	  	Ocean View	  	96704	  	9-2-191-048	  	N/A	  	B2012-0124K	  	2/10/2012

																			
	SOLAR HUB UTILITIES	  	MECO-MAUI
	SCHEDULE 6.14	  
	Permits and Permit Applications	  
	APP
NO.	  	Size
kW
AC	  	PROJECT NAME	  	TMK	  	INSTALL ADDRESS	  	CITY	  	ZIP
CODE	  	TEMP. PERMIT/
BUILDING
PERMIT APP NO.	  	BUILDING
PERMIT NO.	  	PERMIT
ISSUED
	61-2	  	250	  	MLP 5	  	4-3-004:024	  	0 Hui A Road	  	Lahaina	  	96761	  	B T20111305	  	TBD	  	TBD
	61-3	  	250	  	MLP 6	  	4-3-004:025	  	0 Hui A Road	  	Lahaina	  	96761	  	B T20111307	  	TBD	  	TBD
	61-5	  	250	  	MLP 10	  	4-4-002:019	  	0 Honokowai	  	Lahaina	  	96761	  	B T20111319	  	TBD	  	TBD
	61-6	  	250	  	MLP 14	  	4-4-002:016	  	0 Honokowai	  	Lahaina	  	96761	  	B T20111356	  	TBD	  	TBD
	61-12	  	226	  	MLP 15	  	4-2-001:042	  	0 Honoapiilani Hwy	  	Lahaina	  	96761	  	E 20113007
(ELECTRICAL
PERMIT)	  	TBD	  	YES
	61-13	  	250	  	400 HANA Hwy	  	3-8-065-024	  	400 Hana Hwy	  	Kahului	  	96732	  	E 20120012
(ELECTRICAL
PERMIT)	  	TBD	  	YES
	17-1	  	1000	  	MLP 1	  	4-4-004:008	  	0 Honolua	  	Lahaina	  	96761	  	B T20111309	  	TBD	  	TBD
	17-2	  	750	  	MLP 7	  	4-2-001:043	  	0 Honolua	  	Lahaina	  	96761	  	B T20111303	  	TBD	  	TBD

 SCHEDULE 6.15 

LAND CONTRACTS 

																									
	SOLAR HUB UTILITIES	  	HECO-OAHU
	SCHEDULE 6.15	  
	Land Contracts to be assigned by Seller at Closing
 Letters of Intent including all Extensions
	  
	APP
NO.	  	 Size
kW
 AC
	  	PROJECT
NAME	  	TMK	  	INSTALL
ADDRESS	  	CITY	  	ZIP
CODE	  	LOI
ORIGINAL
DROPBOX	  	LOI
EXTENSION
#1
DEADLINE
DROPBOX	  	LOI
EXTENSION
#2
DEADLINE
DROPBOX	  	LOI
EXTENSION
#3
DEADLINE
DROPBOX	  	LOI
EASEMENT
(KAMILONUI
ONLY)
DEADLINE	  	LEASE
EXECUTED
	101
1	  	500	  	HARC CARPORT	  	9-2-001-011	  	94-340 Kunia Rd	  	Waipahu	  	96797	  	7/22/2011	  	2/20/2012	  	5/31/2012	  	9/30/2012	  	N/A	  	
	101
2	  	500	  	KVTHC LOT 7	  	9-2-005-023	  	92-1700 Kunia Rd	  	Wahiawa	  	96786	  	7/22/2011	  	2/29/2012	  	5/31/2012	  	9/30/2012	  	  	
	101
3	  	500	  	THURSTON 1	  	6-2-002-003	  	0000 Kamehameha Hwy	  	Haleiwa	  	96712	  	8/1/2011	  	2/20/2012	  	5/31/2012	  	9/30/2012	  	  	12/3/2011
	101
4	  	500	  	GINELLA 1 -Kawailoa	  	6-1-005-020	  	62-194 Kawailoa Rd	  	Haleiwa	  	96712	  	8/22/2011	  	2/20/2012	  	5/31/2012	  	9/30/2012	  	  	
	101
9	  	500	  	TROPIC LAND 8-7-010-010	  	8-7-010-010	  	87-1233 Hakimo Rd	  	Waianae	  	96792	  	LEASE	  	LEASE	  	LEASE	  	LEASE	  	  	3/16/2012
	101
13	  	198	  	WONG -Punaluu	  	5-3-009-093	  	0000 Puhuli St	  	Hauula	  	96717	  	10/24/2011	  	3/30/2012	  	7/31/2012	  		  	  	
	101
14	  	500	  	TROPIC LAND G 8-7-010-006	  	8-7-010-006	  	87-1239 Hakimo Rd	  	Waianae	  	96792	  	10/17/2011	  	2/20/2012	  	5/31/2012	  	9/30/2012	  	  	
	101
18	  	250	  	965 Kamilonui	  	3-9-019-015	  	965 Kamilonui Place	  	Honolulu	  	96825	  	9/20/2011	  	2/20/2012	  	5/31/2012	  	N/A	  	7/31/2012	  	
	101
19	  	500	  	PLATEAU LOOKOUT	  	5-8-002-004	  	58-378 Kam Highway	  	Haleiwa	  	96712	  	9/17/2011	  	2/29/2012	  	5/31/2012	  	9/30/2012	  	N/A	  	
	101
28	  	500	  	KAUKONAHUA RIDGE	  	6-5-001-043	  	0000 Kaukonahua Rd	  	Waialua	  	96791	  	10/10/2011	  	3/30/2012	  	7/31/2012	  		  	  	
	101
31	  	500	  	KULAAUPUNI	  	8-7-003-008	  	87-204 Kulaaupuni St	  	Waianae	  	96792	  	9/28/2011	  	3/30/2012	  	7/31/2012	  		  	  	
	101
33	  	500	  	KAALA VIEW	  	6-5-001-033	  	0000 Kaukonahua Rd	  	Waialua	  	96791	  	10/4/2011	  	3/30/2012	  	7/31/2012	  		  	  	
	101
36	  	500	  	KAALA LAND	  	6-5-001-010	  	65-670 A Kaukonahua Rd	  	Wahiawa	  	96786	  	11/15/2011	  	5/31/2012	  		  		  	  	
	101
95	  	500	  	KUWALE ROAD	  	8-6-007-002	  	86-335 Kuwale Road	  	Waianae	  	96792	  	11/2/2011	  	5/31/2012	  		  		  	  	
	101
45	  	260	  	OLOMANA GOLF LINKS	  	4-1-013-010	  	41 - 1801 Kalanianaole Hwy	  	Waimanalo	  	96795	  	9/13/2011	  	3/30/2012	  	7/31/2012	  		  	  	
	101
92	  	500	  	WAIANAE VALLEY	  	8-5-004-031	  	85-1330 Waianae Valley Rd	  	Waianae	  	96792	  	11/21/2011	  	5/31/2012	  		  		  	  	
	101
49	  	250	  	958 Kamilonui	  	3-9-019-011	  	958 Kamilonui Place	  	Honolulu	  	96825	  	9/27/2011	  	3/30/2012	  	7/31/2012	  		  	7/31/2012	  	
	101
50	  	250	  	968 Kamilonui	  	3-9-019-012	  	968 Kamilonui Place	  	Honolulu	  	96825	  	9/26/2011	  	3/30/2012	  	7/31/2012	  		  	7/31/2012	  	
	101
51	  	250	  	905 Kamilonui	  	3-9-019-021	  	905 Kamilonui Place	  	Honolulu	  	96825	  	9/28/2011	  	3/30/2012	  	7/31/2012	  		  	7/31/2012	  	
	101
52	  	250	  	898 Kamilonui	  	3-9-019-005	  	898 Kamilonui Place	  	Honolulu	  	96825	  	9/28/2011	  	3/30/2012	  	7/31/2012	  		  	7/31/2012	  	
	101
53	  	250	  	908 Kamilonui	  	3-9-019-006	  	908 Kamilonui Place	  	Honolulu	  	96825	  	9/28/2011	  	3/30/2012	  	7/31/2012	  		  	7/31/2012	  	
	101
54	  	250	  	948 Kamilonui	  	3-9-019-010	  	948 Kamilonui Place	  	Honolulu	  	96825	  	9/28/2011	  	3/30/2012	  	7/31/2012	  		  	7/31/2012	  	
	101
55	  	250	  	918 Kamilonui	  	3-9-019-007	  	918 Kamilonui Place	  	Honolulu	  	96825	  	9/28/2011	  	3/30/2012	  	7/31/2012	  		  	7/31/2012	  	
	101
56	  	250	  	928 Kamilonui	  	3-9-019-008	  	928 Kamilonui Place	  	Honolulu	  	96825	  	9/28/2011	  	3/30/2012	  	7/31/2012	  		  	7/31/2012	  	
	101
57	  	250	  	978 Kamilonui	  	3-9-019-013	  	978 Kamilonui Place	  	Honolulu	  	96825	  	11/22/2011	  	5/31/2012	  		  		  	7/31/2012	  	
	101
58	  	250	  	975 Kamilonui	  	3-9-019-014	  	975 Kamilonui Place	  	Honolulu	  	96825	  	11/15/2011	  	5/31/2012	  		  		  	7/31/2012	  	
	101
59	  	500	  	925 Kamilonui	  	3-9-019-019	  	925 kamilonui Place	  	Honolulu	  	96825	  	9/28/2011	  	3/30/2012	  	7/31/2012	  		  	7/31/2012	  	
	101
60	  	500	  	895 Kamilonui	  	3-9-019-022	  	895 Kamilonui Place	  	Honolulu	  	96825	  	9/28/2011	  	3/30/2012	  	7/31/2012	  		  	7/31/2012	  	
	101
79	  	500	  	Kipapa	  	9-4-005-052	  	94-500 Kam Highway	  	Mililani	  	96789	  	12/2/2011	  	5/31/2012	  		  		  	N/A	  	
	101
85	  	500	  	California Av Lot 1	  	7-5-011-001	  	1818 California Avenue	  	Wahiawa	  	96786	  	12/4/2011	  	5/31/2012	  		  		  	  	
	101
87	  	500	  	Peterson Lot 1	  	9-4-005-010	  	94-500 C Kam Highway	  	Mililani	  	96789	  	12/4/2011	  	5/31/2012	  		  		  	  	
	101
89	  	500	  	Kawiwi 1	  	8-5-034-014	  	87-1038 Kawiwi Way	  	Waianae	  	96792	  	12/12/2011	  	5/31/2012	  		  		  	  	
	101
91	  	500	  	Chen Farms	  	8-5-004-019	  	85-1490 Waianae Valley Rd	  	Waianae	  	96792	  	12/18/2011	  	5/31/2012	  		  		  	  	
	101
97	  	500	  	Kamilonui 945	  	3-9-019-017	  	945 Kamilonui Place	  	Honolulu	  	96825	  	12/23/2011	  	7/31/2012	  		  		  	7/31/2012	  	
	101
98	  	500	  	Kamilonui 955	  	3-9-019-016	  	955 Kamilonui Place	  	Honolulu	  	96825	  	12/23/2011	  	7/31/2012	  		  		  	7/31/2012	  	
	101
99	  	500	  	Kamilonui 915	  	3-9-019-020	  	915 Kamilonui Place	  	Honolulu	  	96825	  	12/23/2011	  	7/31/2012	  		  		  	7/31/2012	  	
	101
100	  	500	  	Kamilonui 855	  	3-9-019-024	  	855 Kamilonui Place	  	Honolulu	  	96825	  	12/23/2011	  	7/31/2012	  		  		  	7/31/2012	  	
	101
101	  	500	  	Kamilonui 865	  	3-9-019-023	  	865 Kamilonui Place	  	Honolulu	  	96825	  	12/23/2011	  	7/31/2012	  		  		  	7/31/2012	  	
	101
102	  	500	  	Costa	  	8-6-005-008	  	86-344 A Kuwale Road	  	Waianae	  	96792	  	12/22/2011	  	7/31/2012	  		  		  	N/A	  	
	101
103	  	500	  	Hawaii Kai	  	3-9-019-025	  	7460 Hawaii Kai Dr	  	Honolulu	  	96825	  	12/20/2011	  	7/31/2012	  		  		  	7/31/2012	  	

																					
	SOLAR HUB UTILITIES	 	MECO—MAUI
	SCHEDULE 6.15	 
	 Land Contracts to be assigned by Seller at Closing

Letters of Intent including all Extensions and Leases
	 
	 APP
 NO.
	 	Size
kW
AC	 	PROJECT
NAME	 	TMK	 	INSTALL ADDRESS	 	CITY	 	ZIP
CODE	 	LOI
ORIGINAL
DROPBOX	 	LOI
EXTENSION
#1 DEADLINE
DROPBOX	 	LOI
EXTENSION
#2 DEADLINE
DROPBOX	 	LEASE SIGNED
	61
 2
	 	250	 	MLP 5	 	4-3-004:024	 		 	Lahaina	 	96761	 	9/2/2011	 	2/29/2012	 	5/31/2012	 	3/19/2012
	61
 3
	 	250	 	MLP 6	 	4-3-004:025	 		 	Lahaina	 	96761	 	9/2/2011	 	2/29/2012	 	5/31/2012	 	3/19/2012
	61
 5
	 	250	 	MLP 10	 	4-4-002:019	 		 	Lahaina	 	96761	 	9/2/2011	 	2/29/2012	 	5/31/2012	 	3/19/2012
	16
 6
	 	250	 	MLP 14	 	4-4-002:016	 		 	Lahaina	 	96761	 	9/2/2011	 	2/29/2012	 	5/31/2012	 	3/19/2012
	61
 12
	 	226	 	MLP 15	 	4-2-001:042	 	Warehouse	 	Lahaina	 	96761	 	9/2/2011	 	2/29/2012	 	5/31/2012	 	3/19/2012
	61
 13
	 	250	 	400 HANA Highway	 	3-8-065:024	 	400 Hana Highway	 	Kahului	 	96732	 	5/3/2011	 	2/29/2012	 	5/31/2012	 	9/30/2012
	17-
 1
	 	1000	 	MLP 1	 	4-4-004:008	 		 	Lahaina	 	96761	 	12/28/2011	 	5/31/2012	 		 	3/19/2012
	17-
 2
	 	750	 	MLP 7	 	4-2-001:043	 		 	Lahaina	 	96761	 	12/28/2011	 	5/31/2012	 		 	3/19/2012

																			
	SOLAR HUB UTILITIES	 	HELCO—KONA (Big Island)
	SCHEDULE 6.15	 
	 Land Contracts to be assigned by Seller at Closing

Letters of Intent including all Extensions
	 
	 APP
 NO.
	 	 Size
 kW
 AC
	 	 PROJECT
 NAME
	 	TMK	 	INSTALL ADDRESS	 	CITY	 	 ZIP
 CODE
	 	 LOI
 ORIGINAL
 DROPBOX
	 	 LOI
 EXTENSION #1
 DEADLINE

DROPBOX
	 	 LOI
 EXTENSION #2
 DEADLINE

DROPBOX

	50
 18
	 	250	 	Kona 1	 	9-2-190-061	 	Maikai Blvd	 	Ocean View	 	96704	 	12/6/2011	 	5/31/2012	 	9/30/2012
	50
 19
	 	250	 	Kona 2	 	9-2-191-047	 	Maikai Blvd	 	Ocean View	 	96704	 	12/6/2011	 	5/31/2012	 	9/30/2012
	50
 20
	 	250	 	Kona 3	 	9-2-187-018	 	Kahili Blvd	 	Ocean View	 	96704	 	12/6/2011	 	5/31/2012	 	9/30/2012
	50
 21
	 	250	 	Kona 4	 	9-2-188-020	 	Lanikai Drive	 	Ocean View	 	96704	 	12/7/2011	 	5/31/2012	 	9/30/2012
	50
 22
	 	250	 	Kona 5	 	9-2-191-034	 	Alii Blvd	 	Ocean View	 	96704	 	12/6/2011	 	5/31/2012	 	9/30/2012
	50
 23
	 	250	 	Kona 6	 	9-2-186-038	 	Kahili Blvd	 	Ocean View	 	96704	 	12/8/2011	 	5/31/2012	 	9/30/2012
	50
 24
	 	250	 	Kona 7	 	9-2-193-049	 	Kona Kai Blvd	 	Ocean View	 	96704	 	12/6/2011	 	5/31/2012	 	9/30/2012
	50
 25
	 	250	 	Kona 8	 	9-2-192-024	 	Alii Blvd	 	Ocean View	 	96704	 	12/6/2011	 	5/31/2012	 	9/30/2012
	50-
 26
	 	250	 	Kona 9	 	9-2-189-096	 	Maile Drive	 	Ocean View	 	96704	 	12/6/2011	 	5/31/2012	 	9/30/2012
	50
 27
	 	250	 	Kona 10	 	9-2-187-034	 	Kahili Blvd	 	Ocean View	 	96704	 	12/6/2011	 	5/31/2012	 	9/30/2012
	50
28	 	250	 	Kona 11	 	9-2-185-084	 	Prince Kuhio Blvd	 	Ocean View	 	96704	 	12/6/2011	 	5/31/2012	 	9/30/2012
	50
29	 	250	 	Kona 12	 	9-2-185-051	 	Maile Drive	 	Ocean View	 	96704	 	12/6/2011	 	5/31/2012	 	9/30/2012
	50
30	 	250	 	Kona 13	 	9-2-189-047	 	Maile Drive	 	Ocean View	 	96704	 	12/6/2011	 	5/31/2012	 	9/30/2012
	50
31	 	250	 	Kona 14	 	9-2-815-071	 	Macadamia Dr	 	Ocean View	 	96704	 	12/6/2011	 	5/31/2012	 	9/30/2012
	50
32	 	250	 	Kona 15	 	9-2-192-012	 	Alii Blvd	 	Ocean View	 	96704	 	12/6/2011	 	5/31/2012	 	9/30/2012
	50
33	 	250	 	Kona 16	 	9-2-189-060	 	Maikai Blvd	 	Ocean View	 	96704	 	12/6/2011	 	5/31/2012	 	9/30/2012
	50
34	 	250	 	Kona 17	 	9-2-190-059	 	Kahili	 	Ocean View	 	96704	 	12/6/2011	 	5/31/2012	 	9/30/2012
	50
35	 	250	 	Kona 18	 	9-2-190-059	 	Maikai Blvd	 	Ocean View	 	96704	 	12/6/2011	 	5/31/2012	 	9/30/2012
	50
36	 	250	 	Kona 19	 	9-2-190-010	 	Alii	 	Ocean View	 	96704	 	12/6/2011	 	5/31/2012	 	9/30/2012
	50
37	 	250	 	Kona 20	 	9-2-191-048	 	Poha Drive	 	Ocean View	 	96704	 	12/6/2011	 	5/31/2012	 	9/30/2012

 SCHEDULE 6.16 

DEVELOPMENT DOCUMENTS 
 Seller/Seller will deliver copies of the Development Documents for the project to be assigned by Seller at Closing. Seller states that all of the assignable documents necessary to complete this
transaction are owned by and are the legal property of the Seller. 
 The Seller will provide DropBox access to the library of Development
Documents that are in Seller’s possession (including Seller’s reasonable access) that exist with regard to the Projects, including, but not limited to: 
  

	 	•	 	 All Notices of Completion issued by the governing Utility; 

 

	 	•	 	 Environmental Studies, Reports, and Permits; 

  

	 	•	 	 Project Engineering; 

  

	 	•	 	 Construction bids; 

  

	 	•	 	 Construction Studies, Reports, and Permits (including all CAD drawings); 

 

	 	•	 	 Electrical Studies, Reports, and Permits; 

  

	 	•	 	 Interconnection Studies, Reports, Applications, Permits, and Approvals with the appropriate Utility; 

 

	 	•	 	 Proposed Lease Documents; 

  

	 	•	 	 The Power Purchase Agreement; 

  

	 	•	 	 Storm water management plan and erosion control permits; 

 

	 	•	 	 Hydrology Reports and mitigation measures, if any; 

  

	 	•	 	 Water well documentation and water rights; 

  

	 	•	 	 Dust control Studies, Reports, and Permits; 

  

	 	•	 	 Site development information, drawings, and studies to date; 

 

	 	•	 	 Access Studies, Reports, and Permits; 

  

	 	•	 	 Access road Studies, Reports, and Permits; 

  

	 	•	 	 Temporary & Permanent fencing design; 

  

	 	•	 	 Land Surveys; 

  

	 	•	 	 Electrical Construction Drawings (completed by Seller and paid out of the Purchase Price); 

 

	 	•	 	 Project (homerun) information/design and drawings; 

  

	 	•	 	 Utility connection information/design and drawings; 

  

	 	•	 	 Grounding Grid information/design and drawings; 

  

	 	•	 	 Engineering Reports and Drawings (to be completed by Seller and paid out of the Purchase Price); 

 

	 	•	 	 Geotechnical Investigation information/design and drawings; 

 

	 	•	 	 PV Layout designs, area information/design, and drawings; 

 

	 	•	 	 Entrance permits to public roads; 

  

	 	•	 	 Reports re onsite temporary storage of spoils; 

  

	 	•	 	 Insurance policies; 

  

	 	•	 	 Start-up information/design and drawings; 

  

	 	•	 	 Meter station information/design and drawings; 

  

	 	•	 	 All local governmental approvals including approved Use Permit; 

 

	 	•	 	 Title reports and copies of all exceptions to title; 

  

	 	•	 	 Transmission easements, rights of way, and other rights; 

 

	 	•	 	 Interconnection and related facilities easement and use agreements; 

 

	 	•	 	 All other studies, reports, and drawings to date. 

 The Seller agrees to take all steps necessary to legally assign the document above as part of the General
Assignment and Bill of Sale (collectively, the “Development Documents”) to Buyer as a condition of the Closing. 
 [Note:
Project specific schedules are set forth in the emails dated June 8, 2012 from Shawn Kent representing Buyer to Robert Bornhoft representing Seller] 

  
 2 

 EXHIBIT A 

PROJECT LIST 

 PROJECT LIST—SOLAR HUB UTILITIES 

HECO-OAHU 
  

													
	 APP
 NO.
	  	SIZE
kW AC	  	PROJECT NAME	  	TMK	  	INSTALL ADDRESS	  	CITY	  	ZIP
CODE
	101     1	  	500	  	HARC CARPORT	  	9-2-001-011	  	94-340 Kunia Rd	  	Waipahu	  	96797
	101     2	  	500	  	KVTHC LOT 7	  	9-2-005-023	  	92-1700 Kunia Rd	  	Wahiawa	  	96786
	101     3	  	500	  	THURSTON 1	  	6-2-002-003	  	0 Kamehameha Hwy	  	Haleiwa	  	96712
	101     4	  	500	  	GINELLA 1—Kawailoa	  	6-1-005-020	  	62-194 Kawailoa Rd	  	Haleiwa	  	96712
	101     9	  	500	  	TROPIC LAND 010	  	8-7-010-010	  	87-1233 Hakimo Rd	  	Waianae	  	96792
	101   13	  	198	  	WONG—Punaluu	  	5-3-009-093	  	0000 Puhuli St	  	Hauula	  	96717
	101   14	  	500	  	TROPIC LAND 006	  	8-7-010-006	  	87-1239 Hakimo Rd	  	Waianae	  	96792
	101   18	  	250	  	965 Kamilonui	  	3-9-019-015	  	965 Kamilonui Place	  	Honolulu	  	96825
	101   19	  	500	  	PLATEAU LOOKOUT	  	5-8-002-004	  	58-378 Kam Highway	  	Haleiwa	  	96712
	101   28	  	500	  	KAUKONAHUA RIDGE	  	6-5-001-043	  	0000 Kaukonahua Rd	  	Waialua	  	96791
	101   31	  	500	  	KULAAUPUNI	  	8-7-003-008	  	87-204 Kulaaupuni St	  	Waianae	  	96792
	101   33	  	500	  	KAALA VIEW	  	6-5-001-033	  	0000 Kaukonahua Rd	  	Waialua	  	96791
	101   36	  	500	  	KAALA LAND	  	6-5-001-010	  	65-670 A Kaukonahua Rd	  	Wahiawa	  	96786
	101   95	  	500	  	KUWALE ROAD	  	8-6-007-002	  	86-335 Kuwale Road	  	Waianae	  	96792
	101   45	  	260	  	OLOMANA GOLF LINKS	  	4-1-013-010	  	41-1801 Kalanianaole Hwy	  	Waimanalo	  	96795
	101   92	  	500	  	WAIANAE VALLEY	  	8-5-004-031	  	85-1330 Waianae Valley Rd	  	Waianae	  	96792
	101   49	  	250	  	958 Kamilonui	  	3-9-019-011	  	958 Kamilonui Place	  	Honolulu	  	96825
	101   50	  	250	  	968 Kamilonui	  	3-9-019-012	  	968 Kamilonui Place	  	Honolulu	  	96825
	101   51	  	250	  	905 Kamilonui	  	3-9-019-021	  	905 Kamilonui Place	  	Honolulu	  	96825
	101   52	  	250	  	898 Kamilonui	  	3-9-019-005	  	898 Kamilonui Place	  	Honolulu	  	96825
	101   53	  	250	  	908 Kamilonui	  	3-9-019-006	  	908 Kamilonui Place	  	Honolulu	  	96825
	101   54	  	250	  	948 Kamilonui	  	3-9-019-010	  	948 Kamilonui Place	  	Honolulu	  	96825
	101   55	  	250	  	918 Kamilonui	  	3-9-019-007	  	918 Kamilonui Place	  	Honolulu	  	96825
	101   56	  	250	  	928 Kamilonui	  	3-9-019-008	  	928 Kamilonui Place	  	Honolulu	  	96825
	101   57	  	250	  	978 Kamilonui	  	3-9-019-013	  	978 Kamilonui Place	  	Honolulu	  	96825
	101   58	  	250	  	975 Kamilonui	  	3-9-019-014	  	975 Kamilonui Place	  	Honolulu	  	96825
	101   59	  	500	  	925 Kamilonui	  	3-9-019-019	  	925 Kamilonui Place	  	Honolulu	  	96825
	101   60	  	500	  	895 Kamilonui	  	3-9-019-022	  	895 Kamilonui Place	  	Honolulu	  	96825
	101   79	  	500	  	Kipapa	  	9-4-005-052	  	94-500 Kam Highway	  	Mililani	  	96789
	101   85	  	500	  	California Av Lot 1	  	7-5-011-001	  	1818 California Avenue	  	Wahiawa	  	96786
	101   87	  	500	  	Peterson Lot 1	  	9-4-005-010	  	94-500 C Kam Highway	  	Mililani	  	96789
	101   89	  	500	  	Kawiwi 1	  	8-5-034-014	  	87-1038 Kawiwi Way	  	Waianae	  	96792
	101   91	  	500	  	Chen Farms	  	8-5-004-019	  	85-1490 Waianae Valley Rd	  	Waianae	  	96792
	101   97	  	500	  	Kamilonui 945	  	3-9-019-017	  	945 Kamilonui Place	  	Honolulu	  	96825
	101   98	  	500	  	Kamilonui 955	  	3-9-019-016	  	955 Kamilonui Place	  	Honolulu	  	96825
	101   99	  	500	  	Kamilonui 915	  	3-9-019-020	  	915 Kamilonui Place	  	Honolulu	  	96825
	101 100	  	500	  	Kamilonui 855	  	3-9-019-024	  	855 Kamilonui Place	  	Honolulu	  	96825
	101 101	  	500	  	Kamilonui 865	  	3-9-019-023	  	865 Kamilonui Place	  	Honolulu	  	96825
	101 102	  	500	  	Costa	  	8-6-005-008	  	86-344 A Kuwale Road	  	Waianae	  	96792
	101 103	  	500	  	Hawaii Kai	  	3-9-019-025	  	7460 Hawaii Kai Dr	  	Honolulu	  	96825

 MECO-MAUI 

 

													
	APP
NO.	  	SIZE
kW AC	  	PROJECT NAME	  	TMK	  	INSTALL ADDRESS	  	CITY	  	ZIP
CODE
	61-2	  	250	  	MLP 5	  	4-3-004:024	  	0 Hui A Road	  	Lahaina	  	96761
	61-3	  	250	  	MLP 6	  	4-3-004:025	  	0 Hui A Road	  	Lahaina	  	96761
	61-5	  	250	  	MLP 10	  	4-4-002:019	  	0 Honokowai	  	Lahaina	  	96761
	61-6	  	250	  	MLP 14	  	4-4-002:016	  	0 Honokowai	  	Lahaina	  	96761
	61-12	  	226	  	MLP 15	  	4-2-001:042	  	0 Honoapiilani Hwy	  	Lahaina	  	96761
	61-13	  	250	  	400 HANA Hwy	  	3-8-065-024	  	400 Hana Hwy	  	Kahului	  	96732
	17-1	  	1000	  	MLP 1	  	4-4-004:008	  	0 Honolua	  	Lahaina	  	96761
	17-2	  	750	  	MLP 7	  	4-2-001:043	  	0 Honolua	  	Lahaina	  	96761
	
	HELCO-BIG ISLAND (KONA)
							
	50 18	  	250	  	Kona 1	  	9-2-190-061	  	Maikai Blvd	  	Ocean View	  	96704
	50 19	  	250	  	Kona 2	  	9-2-191-047	  	Maikai Blvd	  	Ocean View	  	96704
	50 20	  	250	  	Kona 3	  	9-2-187-018	  	Kahili Blvd	  	Ocean View	  	96704
	50 21	  	250	  	Kona 4	  	9-2-188-020	  	Lanikai Drive	  	Ocean View	  	96704
	50 22	  	250	  	Kona 5	  	9-2-191-034	  	Alii Blvd	  	Ocean View	  	96704
	50 23	  	250	  	Kona 6	  	9-2-186-038	  	Kahili Blvd	  	Ocean View	  	96704
	50 24	  	250	  	Kona 7	  	9-2-193-049	  	Kona Kai Blvd	  	Ocean View	  	96704
	50 25	  	250	  	Kona 8	  	9-2-192-024	  	Alii Blvd	  	Ocean View	  	96704
	50 26	  	250	  	Kona 9	  	9-2-189-096	  	Maile Drive	  	Ocean View	  	96704
	50 27	  	250	  	Kona 10	  	9-2-187-034	  	Kahili Blvd	  	Ocean View	  	96704
	50 28	  	250	  	Kona 11	  	9-2-185-084	  	Prince Kuhio Blvd	  	Ocean View	  	96704
	50 29	  	250	  	Kona 12	  	9-2-185-051	  	Maile Drive	  	Ocean View	  	96704
	50 30	  	250	  	Kona 13	  	9-2-189-047	  	Maile Drive	  	Ocean View	  	96704
	50 31	  	250	  	Kona 14	  	9-2-185-071	  	Macadamia Dr	  	Ocean View	  	96704
	50 32	  	250	  	Kona 15	  	9-2-192-012	  	Alii Blvd	  	Ocean View	  	96704
	50 33	  	250	  	Kona 16	  	9-2-189-060	  	Maikai Blvd	  	Ocean View	  	96704
	50 34	  	250	  	Kona 17	  	9-2-185-037	  	Kahili	  	Ocean View	  	96704
	50 35	  	250	  	Kona 18	  	9-2-190-059	  	Maikai Blvd	  	Ocean View	  	96704
	50 36	  	250	  	Kona 19	  	9-2-190-010	  	Alii	  	Ocean View	  	96704
	50 37	  	250	  	Kona 20	  	9-2-191-048	  	Poha Drive	  	Ocean View	  	96704

 EXHIBIT B 

BILL OF SALE AND GENERAL ASSIGNMENT AND ASSUMPTION AGREEMENT 

THIS BILL OF SALE AND GENERAL ASSIGNMENT AND ASSUMPTION AGREEMENT (the “Agreement”) is made as of as of June
[    ], 2012 (the “Effective Date”) between Solar Power, Inc., a California corporation (“Assignee”) and Solar Hub Utilities, LLC, a Hawaiian Limited Liability company
(“Assignor”). 
 Reference is made to that certain Solar Development Acquisition and Sale Agreement dated as of
the Effective Date by and between Assignor and Assignee (as amended or supplemented from time to time in writing, the “Purchase Agreement”). Capitalized terms which are used but not defined herein shall have the meaning set forth in
the Purchase Agreement. 
 For good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged by
Assignor, Assignor and Assignee do hereby agree as follows: 
 1. Sale and Assignment of Personal Property. 

(a) Pursuant to the terms of the Purchase Agreement, under which this Agreement is delivered, Assignor hereby sells, transfers, assigns,
delivers, sets over and conveys to Assignee all of Assignor’s right, title and interest in and to all of the Acquired Assets and Development Documents (each as defined in the Purchase Agreement) and all other and other personal property owned
by Assignor now existing or obtained in the future which are pertinent to the development of the Projects identified on Exhibit A attached hereto, including, without limitation, the items listed below: 

 

	 	•	 	 Land Contracts 

  

	 	•	 	 Interconnection Rights and Interconnection Rights Agreements 

 

	 	•	 	 Power Purchase Agreements 

  

	 	•	 	 Conditional Use Permits 

  

	 	•	 	 Ancillary Agreements 

  

	 	•	 	 Books and Records 

  

	 	•	 	 Permits and Permit Applications 

  

	 	•	 	 Project Attributes 

  

	 	•	 	 Reports 

  

	 	•	 	 Solar Data 

(b) The personal property hereby sold, transferred, assigned, delivered, set over and conveyed is being sold on an “as is, where it
is” basis. 

  
 B-1

 2. General Assignment and Assumption. 

(a) Assignor hereby sells, transfers, assigns, delivers, sets over and conveys to Assignee all right, title and interest of Assignor in
and to all of the Acquired Assets, including, without limitation, the following: 
 (i) to the extent assignable, the rights
under all Development Documents, Land Contracts, Interconnection Rights Agreements, Power Purchase Agreements, and Ancillary Agreements, and all FIT applications and reservations in connection with any of the Projects; 

(ii) to the extent they may be transferred under applicable law, all licenses, permits and authorizations presently issued in connection
with the ownership, development, construction or operation of all or any part of the Projects; 
 (iii) to the extent
assignable, any intangible personal property (including any digital format or version of the following) which is necessary or useful in connection with the ownership, improvement or operation of the Projects, including, but not limited to,
warranties,, approvals, guarantees, permits, franchises, drawings, surveys, licenses, entitlements, certificates of occupancy, reports and studies, any claims and causes of action, surveys, maps, transferable utility contracts, plans and
specifications, engineering plans and studies, accounts, deposits, contract rights, and general intangibles, other rights relating to the construction, ownership, use and operation of all or any part of the Projects; 

(iv) (i) through (iii) collectively referred to as the “Assigned Property”. 

(b) Notwithstanding the foregoing, if the assignment and transfer of any of the Assigned Property would cause a breach thereof and if no
required consent to such assignment and transfer has been obtained from the third party involved, then such obligation or instrument shall not be assigned and transferred hereunder, but Assignor shall act as agent for Assignee in order to obtain for
Assignee the benefits under such obligation or instrument; provided, that the foregoing shall not waive or release Assignor from any obligation to obtain any such consent or any liability for the failure to obtain any such consent.

 (c) Assignee hereby assumes all obligations of Assignor in connection with or arising out of the Assigned Property and
accruing after the date hereof. 
 3. Representations and Warranties. Subject to the provisions of Section 4
below, this Bill of Sale and General Assignment and Assumption Agreement is made without recourse and without representation or warranty of any kind whatsoever, express or implied or by operation of law, except as set forth herein. 

4. Purchase Agreement. This Assignment shall in no event enlarge, reduce or otherwise affect the rights or obligations of
the parties as set forth in the Purchase Agreement. 
 5. Further Assurances. At any time and from time to time after the date
hereof, at Assignee’s request and without further consideration, Assignor will take all action necessary to execute and deliver such other instruments of sale, transfer, conveyance, assignment and confirmation and take such action as may be
necessary or appropriate in order to more effectively transfer, convey and assign to Assignee, and to confirm Assignee’s title to, the Acquired Assets, and, to the full extent permitted by law, to assist Assignee in exercising all rights with
respect thereto. 

  
 B-2

 6. Successors and Assigns. This Agreement shall be binding upon and shall inure to
the benefit of the parties hereto and their respective successors and assigns. 
 7. Governing Law. This Agreement shall
be governed by and construed in accordance with the laws of the State of California without regard to conflicts of law principles. 
 8. Counterparts. This Agreement may be executed in two or more counterparts, each of which shall be deemed an original, but all of which together shall constitute one and the same instrument.

 [Signatures appear on following page.] 

  
 B-3

 IN WITNESS THE EXECUTION HEREOF, under seal, in any number of counterpart copies, each of
which shall be deemed to be an original for all purposes, as of the Effective Date. 
  

									
	SELLER:	  	BUYER:
		
	SOLAR HUB UTILITIES, LLC	  	SOLAR POWER, INC.
	  a Hawaii limited liability company	  	  a California corporation
					
	By:	 	  
	 		  	By:	 	  

	Name:	 	  
	 		  	Name:	 	  

	Title:	 	  
	 		  	Title:	 	  

 [SIGNATURE PAGE TO 
 BILL OF SALE AND GENERAL ASSIGNMENT AND ASSUMPTION AGREEMENT] 

  
 B-4

 EXHIBIT C 

(Reserved) 

 EXHIBIT D 

ESCROW AGREEMENT 

 ESCROW AGREEMENT 

This ESCROW AGREEMENT (the “Escrow Agreement”) is made as of June 7, 2012, among SOLAR POWER, INC., a California
corporation (“Buyer”), SOLAR HUB UTILITIES, LLC, a Hawaii limited liability company (“Seller”) and TITLE GUARANTY ESCROW SERVICES, INC. (the “Escrow Holder”). Each of Buyer, Seller and the Escrow Holder is
referred to herein as a “Party,” and collectively as the “Parties.” 
 RECITALS

 A. Buyer and Seller have entered into that certain Solar Development Acquisition and Sale Agreement
(“Purchase Agreement”) dated as of June 7, 2012, pursuant to which Seller sold and transferred and Buyer purchased certain rights, interests and assets (“Acquired Assets”) comprising sixty-eight
(68) solar, photovoltaic electricity generating facilities (each a “Project” and more than one the “Projects”), as further identified on Exhibit A . A copy of the Purchase Agreement has been
provided to Escrow Holder and capitalized terms used, but not defined, in this Escrow Agreement shall have the meanings given to those terms in the Purchase Agreement; 
 B. Pursuant to the terms of the Purchase Agreement, the Purchase Price is payable on a post-Closing basis. Buyer has agreed to make an advance of the Purchase Price to Escrow Holder for distribution to
Seller in an aggregate amount not to exceed Nine Million Dollars ($9,000,000) of which Three Million Dollars ($3,000,000) has been paid to Seller outside of escrow and Six Million Dollars ($6,000,000) remains to be advanced pursuant to the terms of
this Agreement (“Cash Advance”); 
 C. Pursuant to the terms of the Purchase Agreement, Buyer is obligated to
make payments of the Purchase Price for each Project to Escrow Holder for payment to Seller upon the satisfaction by Seller of each of Project Milestones 1-5 and Project Milestone 6, each as defined in the Purchase Agreement, and other terms and
conditions (“Project Payments”); and 
 D. The Parties desire to enter into this Escrow Agreement to provide
for an escrow account (“Escrow Account”) to be established in order to hold and pay the Cash Advance and Project Payments (“Escrow Funds”) in accordance with the terms set forth in this Agreement. 

NOW, THEREFORE, in consideration of the promises and the mutual agreements expressed herein, the Parties agree as follow:

 1. Appointment of Escrow Holder. Buyer and Seller hereby appoint the Escrow Holder to serve as Escrow Holder
hereunder and the Escrow Holder hereby accepts such appointment and agrees to act as Escrow Holder hereunder and to accept, hold and distribute the Escrow Funds in a separate and distinct account (the “Escrow Account”) in accordance
with and subject to the terms and conditions hereof. Buyer and Seller agree to pay Escrow Holder fees for its services under this Agreement as follows: (a) initial set up fee of $750 plus tax and (b) each individual disbursement a fee of
$125 plus tax. Each individual disbursement can be made via check or wire transfer. Hawaii Tax rate is 4.712% 

 2. Deposit of Cash Advance Funds. Subject to the terms and provisions of the
Purchase Agreement terminating Buyer’s obligation to make Cash Advance deposits, Buyer shall deposit the remaining Cash Advance with the Escrow Holder in six (6) installments, as follows: 

2.1 Buyer shall deposit the first installment in the amount of One Million Dollars ($1,000,000 within twenty-four (24) hours of the
execution of the Purchase Agreement, this Agreement, and the establishment of the Escrow Account. 
 2.2 Buyer shall deposit the
second installment in the amount of Five Hundred Thousand Dollars ($500,000) during the week of June 18-22, 2012. 
 2.3
Buyer shall deposit the third installment in the amount of One Million Dollars ($1,000,000) during the week of July 2-6, 2012. 
 2.4 Buyer shall deposit the fourth installment in the amount of One Million Dollars ($1,000,000) during the week of July 9-13, 2012. 

2.5 Buyer shall deposit the fifth installment in the amount of Two Million Dollars ($2,000,000) during the week of July 23-27, 2012.

 2.6 Buyer shall deposit the sixth installment in the amount of Five Hundred Thousand Dollars ($500,000) within seven
(7) days after Buyer receives notice from Escrow Holder that the balance remaining in the Escrow Account is less than One Million Dollars ($1,000,000). 
 To avoid delays, not less than 48 hours prior to a scheduled disbursement, deposits need to be made by wire transfer. Escrow Holder shall verify that all deposits have been cleared by the financial
institution into which they are deposited before funds can be disbursed. Funds received in this escrow may be deposited with other escrow funds in any federally-insured Hawaii financial institution. The parties acknowledge that federal law and
regulations limit the amount of insurance on insured deposit accounts per depositor. For insurance coverage, see www.fdic.gov. Escrow may have other deposit accounts in the financial institution in which the funds for this escrow are deposited. The
cumulative effect of other accounts of Escrow Holder may limit the amount of insurance available for the funds deposited in this escrow. The parties agree that Escrow Holder has no liability in the event of failure, insolvency or inability of a
financial institution to pay any funds so deposited, including earnings thereon. The sole responsibility of Escrow Holder is to make the deposit. 
 3. Disbursement of Cash Advance Funds. Cash Advance funds shall be disbursed in accordance with the Seller Expense Schedule attached as Exhibit B, as follows: 

3.1 Upon written request of Seller to Escrow Holder, with copy to Buyer, which request shall not be more than five (5) times per
calendar month, Escrow Holder shall release the Overhead portion of the Cash Advance for such calendar month directly to the Seller; provided that, as of the date of such request, the amount of such request for such calendar month coupled with all
prior advances for Overhead for such calendar month does not exceed the cumulative amount authorized under the Seller Expense Schedule to be released by the Escrow Holder for Overhead for such calendar month, or such request is consented to in
writing by the Buyer. 

  
 2 

 3.2 Within three (3) business days after written request of Seller to Escrow Holder,
and simultaneously copied to Buyer and coupled with third party invoices, Escrow Holder shall pay the Project Cost portion of the Cash Advance by check or wire transfer to the identified third party payee; provided that, as of the date of any such
request, the amount of such request coupled with all prior advances for Project Costs from the same specified line item as the line item for such request does not exceed the cumulative amount authorized under the Seller Expense Schedule to be
released by the Escrow Holder as of such date for Project Costs from such specified line item, or, if such request does exceed the cumulative authorized amount, such request is consented to in writing by the Buyer. 

3.3 Buyer’s consent shall be required for the release and payment by the Escrow Holder of any payments requested by Seller from the
Escrow Account for amounts not authorized as provided above or in excess of the amounts set forth in the Seller Expense Schedule. The written approval of Buyer and Seller shall be required for any amendment of the Seller Expense Schedule.

 4. Deposit of Project Payment Funds. Within seven (7) days after written notice by Seller to Buyer and
Escrow Holder asserting satisfaction by Seller of Project Milestones 1 – 5, as set forth in the Purchase Agreement, for any Project, which notice shall include reasonable written evidence of the satisfaction of such Project Milestones, Buyer
shall deposit the Purchase Price for such Project with Escrow Holder for deposit in the Escrow Account. Notwithstanding the foregoing, the deposit of the Purchase Price shall be subject to the Cash Advance crediting provisions set forth in
Section 5.3 below. 
 5. Disbursement of Project Payment Funds. Following the timely deposit by Buyer of the
applicable portion of the Purchase Price for a Project in accordance with Section 4 above, Escrow Agent shall disburse the applicable Purchase Price as follows: 
 5.1 Upon receipt by Escrow Holder of a release by Seller of its security interest under the Security Agreement in the applicable Project and all Acquired Assets solely and directly related to such
Project, which release is reasonably approved by Buyer in writing, Escrow Holder shall (1) release to Seller seventy five percent (75%) of the Purchase Price with respect to the Project, and (2) provide written confirmation to Seller
that it has received payment of the remaining twenty five percent (25%) of the Purchase Price for such Project. Notwithstanding the foregoing, the release of the Purchase Price shall be subject to the Cash Advance crediting provisions set forth
in Section 5.3 below. 
 5.2 With respect to the payment of the remaining twenty five percent (25%) of the Purchase
Price for such Project: 
 (i) If there is no Cash Advance balance then outstanding after first accounting for the payment of the
seventy five percent (75%) of the Purchase Price with respect to the Project pursuant to Section 5.1 above, within seven (7) days after written notice by Seller to Buyer and Escrow Holder asserting satisfaction by Seller of Project
Milestone 6, as set forth in 

  
 3 

 
the Purchase Agreement, for any Project, which notice shall include reasonable written evidence of the satisfaction of such Project Milestone, Escrow Holder shall release to Seller the remaining
twenty five percent (25%) of the Purchase Price for such Project, unless Buyer issues a payment dispute to Seller and Escrow Holder during such period, which payment dispute shall describe with specificity the basis for such dispute and which
shall include supporting documentation to the extent reasonably available to Buyer. Notwithstanding the foregoing, the release of the Purchase Price shall be subject to the Cash Advance crediting provisions set forth in Section 5.3 below.

 (ii) If there is a Cash Advance balance then outstanding after first accounting for the payment of the seventy five percent
(75%) of the Purchase Price with respect to the Project pursuant to Section 5.1 above, then Seller shall be paid the lesser of (a) the remaining twenty five percent (25%) of the Purchase Price or (b) the amount of the Cash
Advance balance concurrently with the payment of the seventy five percent (75%) of the Purchase Price with respect to such Project pursuant to Section 5.1 above, with the payment of such portion of the Purchase Price pursuant to this
Section 5.2(ii) entirely in the form of a credit against the Cash Advance balance and which shall reduce the Cash Advance balance by the amount of the credit. If the Cash Advance balance is completely eliminated pursuant to the preceding
sentence prior to payment in full of the entire remaining twenty five percent (25%) of the Purchase Price, then any remaining portion of the Purchase Price shall be paid in the manner provided in Section 5.2(i) above. 

5.3 Notwithstanding the foregoing, the following provisions shall apply to the calculation, deposit and disbursement of the Project
Payments for each Project under this Section 5: 
 (i) Buyer shall defer payment of the Purchase Price and Project Payments
on Projects otherwise entitled to a Project Payment until July 15, 2012, on which date Buyer shall pay all deferred Project Payments. 
 (ii) Notwithstanding the foregoing, the Cash Advance shall be partially creditable against the Purchase Price and any Project Payments due and payable (i) with respect to the 75% of the Project
Payment to be deposited and released pursuant to Sections 4 and 5.1, on a Fifty Cents ($0.50) per each dollar basis, such that for each payment of One Dollar ($1.00) of the Purchase Price and any Project Payment due to the Seller as provided herein,
the Buyer shall reduce the cash payment of such One Dollar ($1.00) by Fifty Cents ($0.50) and which shall reduce the Cash Advance balance by Fifty Cents ($0.50), until such time as the Cash Advance balance is reduced to Zero Dollars ($0), and
(ii) with respect to the 25% of the Project Payments to be deposited and released pursuant to Sections 4 and 5.2, on a dollar for dollar basis, such that for each payment of One Dollar ($1.00) of the Purchase Price and any Project Payment due
to the Seller as provided herein, the Buyer shall reduce the cash payment of such One Dollar ($1.00) by One Dollar ($1.00) and which shall reduce the Cash Advance balance by One Dollar ($1.00), until such time as the Cash Advance balance is reduced
to Zero Dollars ($0) . 
 5.4 Notwithstanding the foregoing, Buyer shall not be obligated to make a payment of the Cash Advance
under Section 4, and Seller shall not be entitled to obtain Cash 

  
 4 

 
Advance disbursements under Section 5 during any time that Buyer has noticed a Seller Event of Default under the Purchase Agreement which has not been cured. 

6. Joint Written Instructions and Directions; Disbursements. Buyer and Seller may give joint written instructions to Escrow
Holder at any time with respect to the Escrow Funds, or any part thereof, notwithstanding any other provisions of this Escrow Agreement. The Parties agree that all disbursements required to be made hereunder shall be made by wire transfer of
immediately available funds in accordance with the wire transfer instructions specified in the notice directing the Escrow Holder to make such disbursement. Additionally, the provisions of the Purchase Agreement relating to the release of Escrow
Funds upon the occurrence of the termination of the Purchase Agreement, and otherwise as set forth therein, shall be incorporated herein by this reference. 
 7. Provisions Concerning the Escrow Holder. 
 7.1. If, pursuant to
Section 5.2, either Buyer or Seller provides a payment dispute notice, then Escrow Holder will retain the entire disputed amount in the Escrow Account and will not make any distribution of the disputed amount until Escrow Holder receives joint
written instruction from Buyer and Seller, or a notice of a final award of the arbitrator(s) rendered pursuant to the dispute resolution procedures set forth in Section 11.3 of the Purchase Agreement, or a court order from a court of competent
jurisdiction, at which point Escrow Holder will disburse the disputed amount in accordance with such joint written instructions, arbitration award or court order, as applicable. 

7.2. This Escrow Agreement sets forth, exclusively, the duties of the Escrow Holder and no additional duties or obligations shall be
inferred herefrom or implied hereby. 
 7.3. The Escrow Holder shall not be responsible for the validity of any documents or
other property delivered to it pursuant hereto, may act and rely conclusively upon any instrument or signature believed by it to be genuine and may assume that any person purporting to give any notice or instructions hereunder, believed by the
Escrow Holder to be authorized, has been duly authorized so to do. Escrow Holder may rely on the sufficiency of the notices and payment disputes, if any, delivered by a Party to the Escrow Holder and shall not be responsible for determining the
reasonableness or specificity of such notices or payment disputes as described in paragraphs 4, 5.2 above. 
 7.4. The Escrow
Holder shall not be liable for any error of judgment, or for any act done or step taken or omitted by it in good faith, or for any mistake of fact or law, or for anything which it may in good faith do or refrain from doing in connection herewith,
except to the extent that any act or omission constitutes gross negligence or willful misconduct. In no event shall the Escrow Holder be liable for special, indirect or consequential loss or damage of any kind whatsoever (including, but not limited
to, lost profits), even if the Escrow Holder has been advised of such loss or damage and regardless of the form of action. 

7.5. The Escrow Holder may consult with, and obtain advice from, legal counsel in the event of any dispute or question as to the
construction of any of the 

  
 5 

 
provisions hereof or its duties hereunder, and it shall incur no liability and shall be fully protected in acting in good faith in accordance with the advice of such counsel. 

7.6. The Escrow Holder shall not be bound by any modification of this Escrow Agreement unless it shall have specifically consented thereto
in writing. 
 7.7. Buyer and Seller shall each be responsible for and shall pay to the Escrow Holder fifty percent
(50%) all reasonable expenses, including the reasonable fees and expenses of counsel, which the Escrow Holder may incur, and its normal fees for all services rendered, in each case in connection with the discharge of its duties, and the
exercise or enforcement of the rights of the Parties hereunder. The Escrow Holder may deduct any unpaid fees from the Escrow Funds. In the event the Escrow Holder deducts any unpaid fees from the Escrow Funds, the responsible Buyer or Seller party,
as applicable, shall promptly deposit into the Escrow Account an amount equal to such deducted amount. In the event that the deducted fees are the responsibility of Seller, Escrow Holder may offset such deducted fees from disbursements to Seller
under Sections 3 and 5 above. 
 7.8. The Escrow Holder may resign by giving written notice to Buyer and Seller specifying a date
which such resignation shall take effect, which shall in no event be earlier than ten (10) days after the giving of such notice, and shall be discharged from its duties and obligations upon the appointment of a successor Escrow Holder as
hereafter provided and the delivery to such successor of the Escrow Funds. Immediately upon receipt of such notice, Buyer and Seller shall appoint a successor Escrow Holder who shall be mutually acceptable to them. Any such successor Escrow Holder
shall deliver to Buyer and Seller and to the resigning Escrow Holder a written instrument accepting such appointment hereunder, and thereupon it shall succeed to all the rights and duties of the Escrow Holder hereunder, and shall be entitled to
receive the Escrow Funds. In the event that a successor Escrow Holder shall not be so appointed by the date of resignation specified by the Escrow Holder, the Escrow Holder shall have the right to appoint a successor Escrow Holder, and the Parties
hereto agree to accept any such successor Escrow Holder appointed by the Escrow Holder. 
 7.9. In the event of any dispute
between Buyer and Seller or between the Escrow Holder and any one or more of the other Parties hereto, with regard to the Escrow Holder or its duties, or any other matter concerning the disposition of the Escrow Funds or in the event that the Escrow
Holder, in good faith, is in doubt as to what action it should take hereunder, the Escrow Holder may file a suit in interpleader and request that the Escrow Funds be deposited with the First Circuit Court of the State of Hawaii pending the decision
of such court, and the Escrow Holder shall be entitled to refrain from action pending, and rely upon, the decision of such court. The rights of the Escrow Holder under this Section 7.9 are cumulative of all other rights which it may have by law
or otherwise. 
 7.10. The Parties (other than the Escrow Holder) hereby agree that, the Escrow Holder shall be indemnified from
and against any loss, liability or expense reasonably incurred, without gross negligence, willful misconduct or bad faith on its part, arising out of or in connection with the Escrow Agreement, including the expense of defending itself against any
claim or liability arising therefrom. Any payment required to be made pursuant to this Section 7.10 shall be paid from the Escrow Fund. The Escrow Holder shall not be required to give any

  
 6 

 
bond or surety or report to any court despite any statute, custom or rule to the contrary. The Escrow Holder may deduct any unpaid amounts from the Escrow Funds. 

7.11. Buyer and Seller together may terminate the appointment of the Escrow Holder hereunder upon written notice specifying the date upon
which such termination shall take effect. In the event of such termination, Buyer and Seller shall before the date of such termination jointly appoint a successor Escrow Holder, and the Escrow Holder shall deliver the remaining Escrow Funds to such
successor Escrow Holder. 
 8. Notices and Written Directions. All notices, requests, demands, and other
communications required or permitted under this Agreement shall be in writing and shall be deemed to have been duly given and made upon being delivered either by courier or fax delivery to the Party for whom it is intended, provided that a copy
thereof is deposited, postage prepaid, certified or registered mail, return receipt requested, in the United States mail, bearing the address shown in this Section 8 for, or such other address as may be designated in writing hereafter by, such
Party: 
  

			
	If to Seller:	  	 Pat Shudak
 Managing
Member
 Solar Hub Utilities, LLC
 2937
Kalakaua Avenue #23
 Honolulu, HI 96815
  

Email: pshudak@sehsolar.com

		
	with copies to:	  	 Quarles & Brady LLP

Renaissance Square One
 Two North Central
Avenue
 Phoenix, Arizona 85004-2391
  

Attention: Michelle De Blasi
 Facsimile:
(602) 420-5149
 Telephone: (602) 229-5448
 Email: michelle.deblasi@quarles.com

		
	If to Buyer:	  	 Solar Power, Inc.
 2240
Douglas Blvd., Suite 200
 Roseville, CA 95661
  

Attention: Stephen Kircher
 Facsimile:
(916) 770-8194
 Telephone: (916) 770-8100
 Email: skircher@spisolar.com

		
	with copies to:	  	 Solar Power, Inc,
 201
California Street, Suite 1250
 San Francisco, CA 94111
  

Attention: Jim Pekarsky
 Facsimile:

Telephone:
 Email:
JPekarsky@spisolar.com

  
 7 

			
		
	and with copies to:	  	 Weintraub Genshlea Chediak Tobin & Tobin
 400 Capitol Mall, Suite 1100
 Sacramento, CA 95814

 
 Attention: David C. Adams
 Facsimile: (916) 446-1611
 Telephone: (916) 558-6000

Email: dadams@weintraub.com

							
			
	If to Escrow Holder, to:	  		  	
		  	Title Guaranty Escrow Services, Inc.	  	
			
		  	  
	  	
			
		  	  
	  	
			
		  	  
	  	
		  	Attn: 	  	  
	  	
		  	Facsimile: 	  	  
	  	

 9. Counterparts. Counterpart copies of this Escrow Agreement may be signed by all Parties
and signature pages exchanged by fax or otherwise. The Parties intend that counterpart copies signed and exchanged as provided in the preceding sentence shall be fully binding. Counterpart originals of this Escrow Agreement shall be exchanged by
U.S. mail or express service at the earliest reasonable date following the exchange of signature pages by fax. 
 10.
Amendment; Waiver. No modification, amendment or waiver of any provision of this Escrow Agreement will be effective unless such modification, amendment or waiver is approved in writing by Buyer, Seller and the Escrow Holder. The
failure of any Party to enforce any of the provisions of this Escrow Agreement will in no way be construed as a waiver of such provisions and will not affect the right of such Party thereafter to enforce each and every provision of this Escrow
Agreement in accordance with its terms. 
 11. Binding Effect; Assignment. This Escrow Agreement shall be binding
upon and inure to the benefit of the respective successors and permitted assigns of the Parties hereto. 
 12.
Headings. The headings of the various sections of this Escrow Agreement have been inserted for convenience of reference only and shall not be deemed to be a part of this Escrow Agreement. 

13. Severability. If any provision of this Escrow Agreement shall be determined to be illegal or unenforceable, the
remaining provisions of this Escrow Agreement shall remain in full force and effect, and this Escrow Agreement shall be construed as if the illegal or unenforceable provision were not a part hereof, so long as the remaining provisions of this Escrow
Agreement shall be sufficient to carry out the overall intent of the Parties as expressed herein. 

  
 8 

 14. Governing Law. This Escrow Agreement shall be governed by and construed
in accordance with the laws of the State of Hawaii, without regard to its conflicts of law doctrine 
 15. Further
Assurances. Each Party hereto shall perform all other acts and execute and deliver all other documents as may be necessary or appropriate to carry out the purposes and intent of this Escrow Agreement. 

 
 [Signatures appear on following page.] 

  
 9 

 IN WITNESS WHEREOF, the parties hereto have executed this Escrow Agreement as of the
date first set forth above. 
  

			
	SOLAR POWER, INC.
		
	By:	 	 
		
	Name: 	 	 
		
	Title:	 	 
	
	SOLAR HUB UTILITIES, LLC
		
	By:	 	 
		
	Name: 	 	 
		
	Title:	 	 
	
	TITLE GUARANTY ESCROW SERVICES, INC.
		
	By:	 	 
		
	Name: 	 	 
		
	Title:	 	 

  
 10 

 EXHIBIT E 

SECURITY AGREEMENT 
 [See Exhibit 10.2] 

 EXHIBIT F 

(Reserved)Security Agreement

 Exhibit 10.2 
 SECURITY AGREEMENT 
 This SECURITY AGREEMENT (this
“Agreement”), dated as of June 7, 2012, is entered into between SOLAR POWER, INC., a California corporation (the “Debtor”), and SOLAR HUB UTILITIES, LLC, a Hawaiian limited liability company (the
“Secured Party”). 
 WHEREAS, the Debtor and the Secured Party are the parties to a purchase and sale
transaction evidenced by that Solar Development Acquisition and Sale Agreement of on or about even date herewith, between the Secured Party, as seller, and the Debtor, as buyer (the “SDASA”), pursuant to which the Secured Party is
conveying to the Debtor all of the assets described on Schedule A attached hereto (the “Solar Assets”); and 
 WHEREAS, as a requirement in connection with the closing of the transaction contemplated by the SDASA, the Debtor has agreed to execute and deliver to the Lender this Security Agreement, evidencing the
Debtor’s obligation to pay and perform the Obligations (defined below); and 
 WHEREAS, to secure payment and performance
of the Obligations, the Debtor has agreed to grant security interests in favor of the Secured Party as herein provided; 
 NOW,
THEREFORE, in consideration of the promises contained herein and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties hereto agree as follows: 

1. Definitions. The term “State”, as used herein, means the State of California. All terms defined in the Uniform
Commercial Code of the State and used herein shall have the same definitions herein as specified therein. However, if a term is defined in Article 9 of the Uniform Commercial Code of the State differently than in another Article of the Uniform
Commercial Code of the State, the term has the meaning specified in Article 9. The term “Obligations”, as used herein, means all of the indebtedness, obligations and liabilities of the Debtor to the Secured Party arising from or in
connection with the SDASA, the closing and performance of any the transactions contemplated in the SDASA, this Security Agreement and any other document or agreement executed or provided in connection with any of the foregoing documents or
transactions, whether direct or indirect, joint or several, absolute or contingent, due or to become due, now existing or hereafter arising. The term “Transaction Document” means each and every document and agreement executed or
provided in connection with the closing and performance of any the transactions contemplated in the SDASA or this Security Agreement. The term “Real Property Rights” means any right, title or interest in real property held by the
Debtor at any time with respect to any real property upon which any Project is located, and such term includes, without limitation, all of the real property rights and interests now existing or hereafter acquired by the Debtor in any of the
Properties or pursuant to any of the Land Contracts. All other capitalized terms used herein or in any schedule attached hereto that are not defined herein shall have the meanings given to those terms in the SDASA. 

2. Grant of Security Interest. The Debtor hereby grants to the Secured Party, to secure the payment and performance in full of all
of the Obligations, a security interest in, and pledges and assigns to the Secured Party, all right, title and interest of the Debtor in the Solar Assets, wherever located, whether now owned or hereafter acquired or arising, and all proceeds and
products thereof (collectively, the “Collateral”). 

 3. Authorization to File Financing Statements. The Debtor hereby irrevocably
authorizes the Secured Party at any time and from time to time to file in any Uniform Commercial Code jurisdiction any initial financing statements and amendments thereto that (a) indicate the Collateral regardless of whether any particular
asset comprised in the Collateral falls within the scope of Article 9 of the Uniform Commercial Code of the State or such jurisdiction, and (b) contain any other information required by part 5 of Article 9 of the Uniform Commercial Code of
the State for the sufficiency or filing office acceptance of any financing statement or amendment, including whether the Debtor is an organization, the type of organization and any organization identification number issued to the Debtor. The Debtor
agrees to furnish any such information to the Secured Party promptly upon request. The Debtor also ratifies its authorization for the Secured Party to have filed in any Uniform Commercial Code jurisdiction any like initial financing statements or
amendments thereto if filed prior to the date hereof. 
 4. Other Actions. Further to insure the attachment, perfection
and first priority of, and the ability of the Secured Party to enforce, the Secured Party’s security interest in the Collateral, the Debtor agrees, in each case at the Debtor’s own expense, to take any other action reasonably requested by
the Secured Party to insure the attachment, perfection and first priority of, and the ability of the Secured Party to enforce, the Secured Party’s security interest in any and all of the Collateral including, without limitation,
(a) executing, delivering and, where appropriate, filing financing statements and amendments relating thereto under the Uniform Commercial Code, to the extent, if any, that the Debtor’s signature thereon is required therefor,
(b) causing the Secured Party’s name to be noted as secured party on any certificate of title for a titled good if such notation is a condition to attachment, perfection or priority of, or ability of the Secured Party to enforce, the
Secured Party’s security interest in such Collateral, (c) complying with any provision of any statute, regulation or treaty of the United States as to any Collateral if compliance with such provision is a condition to attachment,
perfection or priority of, or ability of the Secured Party to enforce, the Secured Party’s security interest in such Collateral. 
 5. Reserved. 
 6. Reserved. 

7. Representations, Warranties and Covenants Concerning Debtor’s Legal Status. The Debtor represents and warrants to the
Secured Party as follows: (a) the Debtor’s exact legal name is that indicated on the signature page hereof, (b) the Debtor is a corporation organized, validly existing and in good standing in the jurisdiction of California,
(c) the Debtor’s organizational identification number, if it has one, is as indicated on the signature page hereof, (d) the Debtor’s mailing address is as indicated on the signature page hereof, and (e) the Debtor is fully
authorized and permitted to execute and deliver this Agreement. The Debtor covenants with the Secured Party as follows: (a) without providing at least thirty (30) days prior written notice to the Secured Party, the Debtor will not change
its name, its mailing address or organizational identification number if it has one, and (b) the Debtor will not change its jurisdiction of organization or domicile. 
 8. Covenants Concerning Collateral, Etc. Subject in each case to Secured Party’s obligations under the SDASA, the Debtor further covenants with the Secured Party as follows: (a) the
Collateral, to the extent it consists of information and documentation relating to Accounts, contracts rights and Documents not delivered to the Secured Party pursuant to the terms hereof, will be kept only at the address of the Debtor set forth on
the signature page hereof or other locations approved by Lender, and the Debtor will not remove the Collateral from such locations, without providing at least thirty (30) days prior written notice to the Secured Party, (b) except for the
security interest herein granted, the Debtor shall be the owner of the Collateral and the Real Property Rights free from any lien, security interest or 

  
 -2-

 
other encumbrance, and the Debtor shall defend the same against all claims and demands of all persons at any time claiming the same or any interests therein adverse to the Secured Party except
such liens, security interests and encumbrances existing immediately prior to the conveyance of the Solar Assets from Secured Party to Debtor pursuant to the SDASA and continuing thereafter, (c) the Debtor shall not pledge, mortgage, encumber
or create, or suffer to exist a lien or security interest in the Collateral or any Real Property Rights in favor of any person other than the Secured Party, (d) the Debtor will permit the Secured Party, or its designee, to inspect the
Collateral and the real property in which the Debtor has any Real Property Rights at any reasonable time, wherever located, (e) the Debtor will pay (or cause to be paid) promptly when due all taxes, assessments, governmental charges and levies
upon the Collateral or incurred in connection with the use or operation of such Collateral or incurred in connection with this Agreement or relating to the real property in which the Debtor has any Real Property Rights, (f) the Debtor will
continue to operate, its business in compliance with all applicable federal, state and local laws, statutes and ordinances, (g) the Debtor will not sell or otherwise dispose, or offer to sell or otherwise dispose, of the Collateral or any
interest therein or any Real Property Rights, except for sales of inventory in the ordinary course of business; and (h) the Debtor will comply at all times with all Land Contracts and all other agreements evidencing or relating to the
Collateral or any Real Property Rights. 
 9. Insurance. 

9.1 Maintenance of Insurance. The Debtor will maintain with financially sound and reputable insurers insurance with respect to its
properties and business against such casualties and contingencies as shall be in accordance with general practices of businesses engaged in similar activities in similar geographic areas. Such insurance shall be in such minimum amounts that the
Debtor will not be deemed a co-insurer under applicable insurance laws, regulations and policies. In addition, all such insurance shall be payable to the Secured Party as loss payee. 

9.2 Insurance Proceeds. The proceeds of any casualty insurance in respect of any casualty loss of any of the Collateral shall,
subject to the rights, if any, of other parties with a prior interest in the property covered thereby, be held by the Secured Party as cash collateral for the Obligations. The Secured Party may, at its sole option, disburse from time to time all or
any part of such proceeds so held as cash collateral, upon such terms and conditions as the Secured Party may reasonably prescribe, for direct application by the Debtor solely to the repair or replacement of the Debtor’s property so damaged or
destroyed, or the Secured Party may apply all or any part of such proceeds to the Obligations. 
 9.3 Notice of Cancellation,
etc. All policies of insurance shall provide for at least ten (10) days prior written cancellation notice to the Secured Party. In the event of failure by the Debtor to provide and maintain insurance as herein provided, the Secured Party
may, at its option, provide such insurance and charge the amount thereof to the Debtor. The Debtor shall furnish the Secured Party with certificates of insurance and policies evidencing compliance with the foregoing insurance provision. 

10. Collateral Protection Expenses; Preservation of Collateral. 

10.1 Expenses Incurred by Secured Party. Subject to Secured Party’s obligations under the SDASA, in its discretion, after not
less than ten (10) days prior written notice to the Debtor (except in the event of an emergency), the Secured Party may discharge taxes and other encumbrances at any time levied or placed on any of the Collateral or any Real Property Rights,
make repairs thereto and pay any necessary filing fees or, if the debtor fails to do so, insurance premiums. The Debtor agrees to reimburse the Secured Party on demand for any and all expenditures so made. The Secured Party shall have no obligation
to the Debtor to make any such expenditures, nor shall the making thereof relieve the Debtor of any default. 

  
 -3-

 10.2 Secured Party’s Obligations and Duties. Anything herein to the contrary
notwithstanding, the Debtor shall remain liable under each contract or agreement comprised in the Collateral to be observed or performed by the Debtor thereunder. The Secured Party shall not have any obligation or liability under any such contract
or agreement by reason of or arising out of this Agreement or the receipt by the Secured Party of any payment relating to any of the Collateral, nor shall the Secured Party be obligated in any manner to perform any of the obligations of the Debtor
under or pursuant to any such contract or agreement, to make inquiry as to the nature or sufficiency of any payment received by the Secured Party in respect of the Collateral or as to the sufficiency of any performance by any party under any such
contract or agreement, to present or file any claim, to take any action to enforce any performance or to collect the payment of any amounts which may have been assigned to the Secured Party or to which the Secured Party may be entitled at any time
or times. The Secured Party’s sole duty with respect to the custody, safe keeping and physical preservation of the Collateral in its possession, under Section 9-207 of the Uniform Commercial Code of the State or otherwise, shall be to deal
with such Collateral in the same manner as the Secured Party deals with similar property for its own account. Notwithstanding the foregoing, the provisions of this Section 102 shall be subject to Secured Party’s obligations under the
SDASA. 
 11. Power of Attorney. 
 11.1 Appointment and Powers of Secured Party. Upon an Event of Default and while such Event of Default is continuing, the Debtor hereby irrevocably constitutes and appoints the Secured Party and
any officer or agent thereof, with full power of substitution, as its true and lawful attorneys-in-fact with full irrevocable power and authority in the place and stead of the Debtor or in the Secured Party’s own name, for the purpose of
carrying out the terms of this Agreement, to take any and all appropriate action and to execute any and all documents and instruments that may be necessary or desirable to accomplish the purposes of this Agreement and, without limiting the
generality of the foregoing, hereby gives said attorneys the power and right, on behalf of the Debtor, upon an Event of Default and while such Event of Default is continuing, but otherwise without notice to or assent by the Debtor, to do the
following: generally to sell, transfer, pledge, make any agreement with respect to or otherwise deal with any of the Collateral in such manner as is consistent with the Uniform Commercial Code of the State and as fully and completely as though the
Secured Party were the absolute owner thereof for all purposes, and to do at the Debtor’s expense, at any time, or from time to time, all acts and things which the Secured Party deems necessary to protect, preserve or realize upon the
Collateral and the Secured Party’s security interest therein, in order to effect the intent of this Agreement, all as fully and effectively as the Debtor might do. This power of attorney is a power coupled with an interest and shall be
irrevocable. The powers conferred on the Secured Party hereunder are solely to protect its interests in the Collateral and shall not impose any duty upon it to exercise any such powers. 

12. Event of Default; Remedies. 
 12.1 Event of Default. Each of the following shall constitute an “Event of Default” hereunder: 
 (a) Any failure or neglect to perform or observe any of the material terms, provisions or covenants of this Agreement, which failure continues unremedied after not less than thirty (30) days written
notice; 
 (b) Any “Event of Default” as defined in the SDASA. 

  
 -4-

 (c) Any breach or default under any Transaction Document that continues unremedied beyond
any notice and cure or grace period expressly applicable thereto. 
 12.2 General Remedies. If an Event of Default shall
have occurred and be continuing, the Secured Party may, without notice to or demand upon the Debtor, and without limiting any of its other rights and remedies upon an Event of Default, declare this Agreement to be in default, and the Secured Party
shall thereafter have in any jurisdiction in which enforcement hereof is sought all rights and remedies available at law and in equity, and in addition thereto, all rights and remedies of a secured party under the Uniform Commercial Code of the
State or of any jurisdiction in which Collateral is located, including, without limitation, the right to take possession of the Collateral, and for that purpose the Secured Party may, so far as the Debtor can give authority therefor, enter upon any
premises on which the Collateral may be situated and remove the same therefrom. The Secured Party may in its discretion require the Debtor to assemble all or any part of the Collateral at such location or locations within the jurisdiction(s) of the
Debtor’s principal office(s) or at such other locations as the Secured Party may reasonably designate. Unless the Collateral is perishable or threatens to decline speedily in value or is of a type customarily sold on a recognized market, the
Secured Party shall give to the Debtor at least ten (10) business days prior written notice of the time and place of any public sale of Collateral or of the time after which any private sale or any other intended disposition is to be made. The
Debtor hereby acknowledges that ten (10) business days prior written notice of such sale or sales shall be reasonable notice. In addition, the Debtor waives any and all rights that it may have to a judicial hearing in advance of the enforcement
of any of the Secured Party’s rights hereunder, including, without limitation, its right following an Event of Default to take immediate possession of the Collateral and to exercise its rights with respect thereto. 

12.3 Reserved. 

12.4 Reserved. 
 12.5 Standards for Exercising Remedies. To the extent that applicable law imposes duties on the Secured Party to exercise remedies in a commercially reasonable manner, the Debtor acknowledges and
agrees that it is not commercially unreasonable for the Secured Party (a) to fail to incur expenses reasonably deemed significant by the Secured Party to prepare Collateral for disposition or otherwise to complete raw material or work in
process into finished goods or other finished products for disposition, (b) to fail to exercise collection remedies against account debtors or other persons obligated on Collateral or to remove liens or encumbrances on or any adverse claims
against Collateral, (c) to exercise collection remedies against account debtors and other persons obligated on Collateral directly or through the use of collection agencies and other collection specialists, (d) to advertise dispositions of
Collateral through publications or media of general circulation, whether or not the Collateral is of a specialized nature, (e) to contact other persons, whether or not in the same business as the Debtor, for expressions of interest in acquiring
all or any portion of the Collateral, (f) to hire one or more professional auctioneers to assist in the disposition of Collateral, whether or not the collateral is of a specialized nature, (g) to dispose of Collateral by utilizing Internet
sites that provide for the auction of assets of the types included in the Collateral or that have the reasonable capability of doing so, or that match buyers and sellers of assets, (h) to dispose of assets in wholesale rather than retail
markets, (i) to disclaim disposition warranties, (j) to purchase insurance or credit enhancements to insure the Secured Party against risks of loss, collection or disposition of Collateral or to provide to the Secured Party a guaranteed
return from the collection or disposition of Collateral, or (k) to the extent deemed appropriate by the Secured Party, to obtain the services of other brokers, investment bankers, consultants and other professionals to assist the Secured Party
in the collection or disposition of any of the Collateral. The Debtor acknowledges that the purpose of this Section is to provide non-exhaustive indications of what actions or omissions by the Secured Party would not be commercially unreasonable in
the Secured Party’s 

  
 -5-

 
exercise of remedies against the Collateral and that other actions or omissions by the Secured Party shall not be deemed commercially unreasonable solely on account of not being indicated in this
Section. Without limitation upon the foregoing, nothing contained in this Section shall be construed to grant any rights to the Debtor or to impose any duties on the Secured Party that would not have been granted or imposed by this Agreement or by
applicable law in the absence of this Section. 
 13. No Waiver by Secured Party, etc. The Secured Party shall not be
deemed to have waived any of its rights upon or under the Obligations or the Collateral unless such waiver shall be in writing and signed by the Secured Party. No delay or omission on the part of the Secured Party in exercising any right shall
operate as a waiver of such right or any other right. A waiver on any one occasion shall not be construed as a bar to or waiver of any right on any future occasion. All rights and remedies of the Secured Party with respect to the Obligations or the
Collateral, whether evidenced hereby or by any other instrument or papers, shall be cumulative and may be exercised singularly, alternatively, successively or concurrently at such time or at such times as the Secured Party deems expedient.

 14. Suretyship Waivers by Debtor. The Debtor waives demand, notice, protest, notice of acceptance of this Agreement,
notice of loans made, credit extended, Collateral received or delivered or other action taken in reliance hereon and all other demands and notices of any description. With respect to both the Obligations and the Collateral, the Debtor assents to any
extension or postponement of the time of payment or any other indulgence, to any substitution, exchange or release of or failure to perfect any security interest in any Collateral, to the addition or release of any party or person primarily or
secondarily liable, to the acceptance of partial payment thereon and the settlement, compromising or adjusting of any thereof, all in such manner and at such time or times as the Secured Party may deem advisable. Except as set forth in the SDASA,
the Secured Party shall have no duty as to the collection or protection of the Collateral or any income thereon, nor as to the preservation of rights against prior parties, nor as to the preservation of any rights pertaining thereto beyond the safe
custody thereof as set forth in Section 10.2. The Debtor further waives any and all other suretyship defenses. Further, the Debtor agrees that it is not necessary for the Secured Party to inquire into the powers of the Debtor or the officers,
directors, partners or agents acting or purporting to act on its behalf for any purpose. Each party comprising the Debtor is and shall continue to be fully informed as to all aspects of the business affairs of each party comprising the Debtor that
it deems relevant to the risks it is assuming and hereby waives and fully discharges the Secured Party from any and all obligations to communicate to either party comprising the Debtor any facts of any nature whatsoever regarding the Debtor’s
business affairs. Neither party comprising the Debtor shall have any right of subrogation and hereby waives any right to enforce any remedy which the Secured Party now has, or may hereafter have, against the other party comprising the Debtor.
Nothing contained herein shall affect or limit the right of the Secured Party to proceed against any person or entity, including the Debtor, with respect to the enforcement of any guarantee or other similar rights, regardless of whether the Secured
Party elects to take any action against the Debtor. 
 15. Marshalling. The Secured Party shall not be required to
marshal any present or future collateral security (including but not limited to this Agreement and the Collateral) for, or other assurances of payment of, the Obligations or any of them or to resort to such collateral security or other assurances of
payment in any particular order, and all of its rights hereunder and in respect of such collateral security and other assurances of payment shall be cumulative and in addition to all other rights, however existing or arising. To the extent that it
lawfully may, the Debtor hereby agrees that it will not invoke any law relating to the marshalling of collateral which might cause delay in or impede the enforcement of the Secured Party’s rights under this Agreement or under any other
instrument creating or evidencing any of the Obligations or under which any of the Obligations is outstanding or by which any of the Obligations is secured or payment thereof is otherwise assured, and, to the extent that it lawfully may, the Debtor
hereby irrevocably waives the benefits of all such laws. 

  
 -6-

 16. Proceeds of Dispositions; Expenses; Attorneys’ Fees. The Debtor shall pay to
the Secured Party on demand any and all expenses, including reasonable attorneys’ fees and disbursements, incurred or paid by the Secured Party in protecting, preserving or enforcing the Secured Party’s rights under or in respect of any of
the Obligations or any of the Collateral. After deducting all of said expenses, the residue of any proceeds of collection or sale of the Obligations or Collateral shall, to the extent actually received in cash, be applied to the payment of the
Obligations in such order or preference as the Secured Party may determine, proper allowance and provision being made for any Obligations not then due. Upon the final payment and satisfaction in full of all of the Obligations and after making any
payments required by Sections 9-608(a)(1)(C) or 9-615(a)(3) of the Uniform Commercial Code of the State, any excess shall be returned to the Debtor. Notwithstanding any other provision of this Agreement, but except as otherwise expressly provided in
the SDASA, the Debtor shall not be liable for any deficiency in the payment of the Obligations. In the event of any action or proceeding involving this Agreement or the Obligations, the prevailing party in such action or proceeding shall be entitled
to an award of its reasonable attorneys’ fees and costs. 
 17. Reserved. 

18. Governing Law; Consent to Jurisdiction. THIS AGREEMENT SHALL BE GOVERNED BY, AND CONSTRUED IN ACCORDANCE WITH, THE LAWS OF THE
STATE. The Debtor agrees that any suit for the enforcement of this Agreement may be brought in the courts of the State or any other state in which the Secured Party has an office or any federal court sitting in the State or any other state in which
the Secured Party has an office. The Debtor hereby consents to the non-exclusive jurisdiction of such courts. The Debtor hereby waives any objection that it may now or hereafter have to the venue of any such suit or any such court or that such suit
is brought in an inconvenient court. 
 19. Waiver of Jury Trial. THE DEBTOR WAIVES ITS RIGHT TO A JURY TRIAL WITH
RESPECT TO ANY ACTION OR CLAIM ARISING OUT OF ANY DISPUTE IN CONNECTION WITH THIS AGREEMENT, ANY RIGHTS OR OBLIGATIONS HEREUNDER OR THE PERFORMANCE OF ANY SUCH RIGHTS OR OBLIGATIONS. Except as prohibited by law, the Debtor waives any right which it
may have to claim or recover in any litigation referred to in the preceding sentence any special, exemplary, punitive or consequential damages or any damages other than, or in addition to, actual damages. The Debtor (i) certifies that neither
the Secured Party nor any representative, agent or attorney of the Secured Party has represented, expressly or otherwise, that the Secured Party would not, in the event of litigation, seek to enforce the foregoing waivers and (ii) acknowledges
that, in entering into this Agreement, the Secured Party is relying upon, among other things, the waivers and certifications contained in this Section. 
 20. Miscellaneous. The headings of each section of this Agreement are for convenience only and shall not define or limit the provisions thereof. All references herein to the “Debtor”
shall be considered separate references to each of the stated parties comprising the Debtor and to such parties collectively, and all representations, warranties, obligations and agreements applicable to the Debtor shall apply separately to each of
the stated parties comprising the Debtor and to such parties collectively. This Agreement and all rights and obligations hereunder shall be binding upon the Debtor and its respective successors and assigns, and shall inure to the benefit of the
Secured Party and its successors and assigns. If any term of this Agreement shall be held to be invalid, illegal or unenforceable, the validity of all other terms hereof shall in no way be affected thereby, and this Agreement shall be construed and
be enforceable as if such invalid, illegal or unenforceable term had not been included herein. The Debtor acknowledges receipt of a copy of this Agreement. This Agreement constitutes the entire agreement of the parties with respect to the matters
discussed herein. This Agreement may only be modified by a written agreement signed by both parties. 

  
 -7-

 [Signatures appear on following page.] 

  
 -8-

 DATED as of the date first set forth above. 

 

			
	SOLAR POWER, INC., a California corporation
		
	By:	 	 /s/ Alan M. Lefko

		 	Alan M. Lefko, Vice President Finance

 
			
	
	Organizational ID No.: C2880869
		
	 Address for

the Debtor:    
	 	2240 Douglas Blvd., Suite 200
		 	Roseville, CA 95661-3875
		 	  

 Accepted as of the date first set forth above: 

 

			
	SOLAR HUB UTILITIES, LLC, a Hawaii limited liability company
		
	By:    	 	 /s/ Pat Shudak

	Name: Pat Shudak
	Title:   Manager

  
 -9-

 SCHEDULE A 
 List of Solar Assets 
 All of Seller’s right, title and interest, without reservations
or restrictions, in and to all of the assets and rights comprising the Projects, whether existing now or in the future, including, without limitation, pursuant to or as reflected in any and all Development Documents, Books and Records, Land
Contracts, Permits, the Permit Applications, Reports, Interconnection Rights, Power Purchase Agreements, Project Attributes, Solar Data, or otherwise with respect to any Project. 
 As used in the preceding paragraph, the following terms shall have the following meanings: 
 1. Projects. The complete portfolio of 68 single solar-powered electricity generating plants (including the Facilities and Interconnection) having a combined nominal nameplate capacity of
29,172,000 watts DC to be located on the various Properties. 
 2. Development Documents. All of the documents and
materials with respect to the Projects, including, without limitation, as listed on Schedule B attached hereto, whether existing now or in the future. 
 3. Books and Records. Any and all data, reports, correspondence, maps, surveys and other business records relating to the Projects that are generated or obtained by Seller prior to Closing (other
than the Solar Data). 
 4. Land Contracts. The letters of intent and Lease Agreements entered into between various
property owners, whether existing now or in the future, including, without limitation, those listed on Schedule C attached hereto, establishing the tangible real property interests, easements, or leases in the Properties. 

5. Permits. The licenses, consents, certificates, approvals, and permits required for the construction, installation, ownership or
operation of the Projects, whether existing now or in the future, including, without limitation, as described on Schedule D attached hereto, including, without limitation, the Conditional Use Permits, if a Conditional Use Permit is required
by Law for the Project. 
 6. Permit Applications. Any and all applications, petitions, filings or requests made to any
Authority, whether existing now or in the future, on or before the Closing Date in order to obtain a Permit for the Project. 

7. Reports. The Phase I Environmental Assessment, the Title Commitments, the Interconnection Studies and the Solar Study.

 8. Interconnection Rights. All rights and interests of the non-Utility party, without reservations or restrictions, in
the Interconnection Agreements. 
 9. Power Purchase Agreement. A power purchase agreement or other evidence of a binding
commitment from the applicable Utility for the purchase of the electricity generated by the Facility, whether existing now or in the future, at a rate not less than $0.238 US per kWh, for a term of not less than twenty (20) years. 

  
 -10-

 10. Project Attributes. The renewable energy certificates or credits, green tags,
emission credits, carbon offsets and any other environmental attribute currently available or available at any time in the future related to each Property, Facilities or Project, as well as all tax credits, including, without limitation, production
tax credits and investment tax credits. 
 11. Solar Data. Any and all solar data with regard to the Projects, whether
existing now or in the future, included, or included by reference, on Schedule E attached hereto. The Solar Data includes the Solar Study. 

  
 -11-

 SCHEDULE B 
 List of Development Documents 
 The Development Documents include, without limitation, all
of the following documents and information: 
  

	 	•	 	 All Notices of Completion issued by the governing Utility; 

 

	 	•	 	 Environmental Studies, Reports, and Permits; 

  

	 	•	 	 Project Engineering; 

  

	 	•	 	 Construction bids; 

  

	 	•	 	 Construction Studies, Reports, and Permits (including all CAD drawings); 

 

	 	•	 	 Electrical Studies, Reports, and Permits; 

  

	 	•	 	 Interconnection Studies, Reports, Applications, Permits, and Approvals with the appropriate Utility; 

 

	 	•	 	 Proposed Lease Documents; 

  

	 	•	 	 The Power Purchase Agreement; 

  

	 	•	 	 Storm water management plan and erosion control permits; 

 

	 	•	 	 Hydrology Reports and mitigation measures, if any; 

  

	 	•	 	 Water well documentation and water rights; 

  

	 	•	 	 Dust control Studies, Reports, and Permits; 

  

	 	•	 	 Site development information, drawings, and studies to date; 

 

	 	•	 	 Access Studies, Reports, and Permits; 

  

	 	•	 	 Access road Studies, Reports, and Permits; 

  

	 	•	 	 Temporary & Permanent fencing design; 

  

	 	•	 	 Land Surveys; 

  

	 	•	 	 Electrical Construction Drawings (completed by Seller and paid out of the Purchase Price); 

 

	 	•	 	 Project (homerun) information/design and drawings; 

  

	 	•	 	 Utility connection information/design and drawings; 

  

	 	•	 	 Grounding Grid information/design and drawings; 

  

	 	•	 	 Engineering Reports and Drawings (to be completed by Seller and paid out of the Purchase Price); 

 

	 	•	 	 Geotechnical Investigation information/design and drawings; 

 

	 	•	 	 PV Layout designs, area information/design, and drawings; 

 

	 	•	 	 Entrance permits to public roads; 

  

	 	•	 	 Reports re onsite temporary storage of spoils; 

  

	 	•	 	 Insurance policies; 

  

	 	•	 	 Start-up information/design and drawings; 

  

	 	•	 	 Meter station information/design and drawings; 

  

	 	•	 	 All local governmental approvals including approved Use Permit; 

 

	 	•	 	 Title reports and copies of all exceptions to title; 

  

	 	•	 	 Transmission easements, rights of way, and other rights; 

 

	 	•	 	 Interconnection and related facilities easement and use agreements; 

 

	 	•	 	 All other studies, reports, and drawings to date. 

  
 -12-

 SCHEDULE C 
 List of Land Contracts 
 [See Schedule 6.15 to Exhibit 10.1] 

  
 -13-

 SCHEDULE C 
 List of Permits 
 [See Schedule 6.14 to Exhibit 10.1] 

  
 -14-

 SCHEDULE E 
 List of Solar Data 
 [See Schedule 6.13 to Exhibit 10.1] 

  
 -15-

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00205-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00205-of-00352.parquet"}]]