Document:

<PAGE>

                                                                EXHIBIT 10.1

                              SYMANTEC CORPORATION

                                       AND

                                AUDIOHIGHWAY.COM

                                      LEASE

<PAGE>

                                SUMMARY OF LEASE

                              CUPERTINO CITY CENTER

1.   DATE OF LEASE:

2.   LANDLORD:                          Symantec Corporation

3.   TENANT:                            Audiohighway.com,
                                        a California corporation

4.   PREMISES:                          20300 Steven Creek Blvd., Suite 100
                                        Cupertino, California 95014

5.   SQUARE FEET:                       26,967 sq. ft.

6.   PERMITTED USE:                     General office use

7.   TERM:                              Five (5) years

     (a) SCHEDULED COMMENCEMENT DATE:   November 1, 1999

     (b) SCHEDULED EXPIRATION DATE:     October 31, 2004

8.   RENT:

     (a) BASIC RENT:                  $79,552.65 per month (Lease months 1-12)
                                      $82,734.76 per month (Lease months 13-24)
                                      $86,044.15 per month (Lease months 25-36)
                                      $89,485.91 per month (Lease months 37-48)
                                      $93,065.35 per month (Lease months 49-60)

     (b) TENANT'S ESTIMATED SHARE OF
         DIRECT EXPENSES:             $19,524.11 per month

9.    SECURITY DEPOSIT:               $400,000

10.   PARKING SPACES PROVIDED:        One Hundred Five (105) spaces

11.   OTHER IMPORTANT PROVISIONS:

12.   EXHIBITS:                        Exhibit A - Premises
                                       Exhibit B - Project
                                       Exhibit C - Work Letter Agreement
                                       Exhibit D - Sublease Recapture Exemption
                                       Space

<PAGE>

THIS SUMMARY OF LEASE IS INTENDED TO SUMMARIZE CERTAIN KEY PROVISIONS IN THE
ATTACHED LEASE. IN THE EVENT OF ANY CONFLICT OR INCONSISTENCY BETWEEN THE
PROVISIONS OF THIS SUMMARY AND THE LEASE, THE PROVISIONS OF THE LEASE SHALL
GOVERN.

<PAGE>

                                TABLE OF CONTENTS

ITEM                                                                     PAGE
-----------------------------------------------------------------------------
1.    USE
2.    TERM
3.    POSSESSION
4.    MONTHLY RENT
5.    ADJUSTMENT OF BASIC RENT AND DIRECT EXPENSES
6.    RESTRICTION ON USE
7.    COMPLIANCE WITH LAWS
8.    ALTERATIONS
9.    REPAIR AND MAINTENANCE
10.   LIENS
11.   INSURANCE
12.   UTILITIES AND SERVICE
13.   TAXES AND OTHER CHARGES
14.   ENTRY BY LANDLORD
15.   COMMON AREA; PARKING
16.   DAMAGE BY FIRE; CASUALTY
17.   INDEMNIFICATION
18.   ASSIGNMENT AND SUBLETTING
19.   DEFAULT
20.   LANDLORD'S RIGHT TO CURE TENANT'S DEFAULT
21.   EMINENT DOMAIN
22.   NOTICE AND COVENANT TO SURRENDER
23.   TENANT'S QUITCLAIM
24.   HOLDING OVER
25.   SUBORDINATION
26.   CERTIFICATE OF ESTOPPEL
27.   SALE BY LANDLORD
28.   ATTORNMENT TO LENDER OR THIRD PARTY
29.   DEFAULT BY LANDLORD
30.   CONSTRUCTION CHANGES
31.   MEASUREMENT OF PREMISES
32.   ATTORNEY FEES
33.   SURRENDER
34.   WAIVER
35.   EASEMENTS; AIRSPACE RIGHTS
36.   RULES AND REGULATIONS
37.   NOTICES
38.   NAME
39.   GOVERNING LAW; SEVERABILITY
40.   DEFINITIONS
41.   TIME
42.   INTEREST ON PAST DUE OBLIGATIONS; LATE CHARGE
43.   ENTIRE AGREEMENT
44.   AUTHORITY

<PAGE>

45.   RECORDING
46.   EXHIBITS AND ATTACHMENTS
47.   REAL ESTATE BROKERS
48.   ENVIRONMENTAL MATTERS
49.   SIGNAGE
50.   SUBMISSION OF LEASE
51.   TENANT IMPROVEMENTS
52.   ADDITIONAL RENT
53.   LANDLORD'S OPTION TO RELOCATE PREMISES

<PAGE>

                                  OFFICE LEASE

         THIS LEASE is made this _____ day of _______________________, 1999, by
and between SYMANTEC CORPORATION, a Delaware corporation, ("Landlord"), and
AUDIOHIGHWAY.COM, a California corporation ("Tenant").

                              W I T N E S S E T H :

         Landlord leases to Tenant and Tenant leases from Landlord those certain
premises outlined in red on Exhibit A (the "Premises") commonly known as 20300
Stevens Creek Boulevard, Suite 100, Cupertino, California, which Landlord and
Tenant hereby agree consists of approximately twenty-six thousand nine hundred
sixty-seven (26,967) square feet. As used herein the term "Project" shall mean
and include all of the land described in Exhibit B and all the buildings,
improvements, fixtures and equipment now or hereafter situated on said land.

         Tenant covenants, as a material part of the consideration of this
lease, to perform and observe each and all of the terms, covenants and
conditions set forth below, and this lease is made upon the condition of such
performance and observance.

         1.       USE

         Subject to the restrictions contained in paragraph 6, Tenant shall
use the Premises for general office use and shall not use or permit the
Premises to be used for any other purpose.

         2.       TERM

                  (a) The term shall be for five (5) years (unless sooner
terminated as hereinafter provided) and, subject to paragraphs 2(b) and 3,
shall commence on November 1, 1999 and end on October 31, 2004.

                  (b) Possession of the Premises shall not be deemed tendered
and the term shall not commence until Landlord notifies Tenant of substantial
completion of all work to be done by Landlord pursuant to Exhibit C to this
lease (exclusive of telephones or other communication systems and punchlist
items) and the Premises can be legally occupied by Tenant, except that (i) if
Landlord is prevented from or delayed in completing its work under Exhibit C to
this lease due to the acts or omissions of Tenant

<PAGE>

or Tenant caused delays (as defined in Exhibit C), then the Premises shall be
deemed tendered and the term shall commence upon the date by which such work
would have been substantially completed but for such acts or omissions of
Tenant and Tenant caused delays, and (ii) if Tenant occupies or otherwise
enters into possession of all or any part of the Premises prior to the
scheduled commencement date, unless otherwise agreed in writing by Landlord,
the term shall commence upon the date of such entry and Tenant's obligation
to pay basic rent and direct expenses shall commence as of such lease
commencement date.

         3.       POSSESSION

                  (a) If Landlord for any reason cannot deliver possession of
the Premises to Tenant by the scheduled commencement date set forth in paragraph
2(a), this lease shall not be void or voidable, Landlord shall not be liable to
Tenant for any loss or damage on account thereof and, unless Landlord's failure
to deliver possession of the Premises to Tenant by the scheduled commencement
date set forth in paragraph 2(a) is caused by the acts or omissions of Tenant or
Tenant caused delays, Tenant shall not be liable for rent until the commencement
of the term is determined in accordance with paragraph 2(b). If the term
commences on a date other than the date specified in paragraph 2(a) above, then
the parties shall immediately execute an amendment to this lease stating (or a
letter acknowledging) the actual date of commencement and the revised expiration
date. The expiration date of the term shall be extended by the same number of
days that Tenant's possession of the Premises was delayed from that set forth in
paragraph 2(a).

                  (b) Tenant's inability or failure to take possession of the
Premises when delivery is tendered by Landlord (with the improvements to be done
pursuant to Exhibit C to this lease substantially completed) shall not delay the
commencement of the term of this lease or Tenant's obligation to pay rent.
Tenant acknowledges that Landlord shall incur significant expenses upon the
execution of this lease, even if Tenant never takes possession of the Premises,
including without limitation brokerage commissions and fees, legal and other
professional fees, the costs of space planning and the costs of construction of
improvements in the Premises. Tenant acknowledges that all of said expenses
shall be included in measuring Landlord's damages should Tenant breach the terms
of this lease.

         4.       MONTHLY RENT

                  (a) BASIC RENT. Tenant shall pay to Landlord as basic rent for
the Premises, in advance and subject to adjustment as provided in paragraph 5,
the sum of Seventy-Nine Thousand Five Hundred Fifty-Two and 65/100 Dollars
($79,552.65) on or before the first day of the first full calendar month of the
term and on or before the first day of each and every successive calendar month.
Basic rent for any partial month shall be payable in advance and shall be
prorated based on the actual number of days during the lease term occurring in
such month divided by the total number of days in such month.

<PAGE>

                  (b) DIRECT EXPENSES. In addition to the above basic rent and
as additional rent, Tenant shall pay to Landlord, subject to adjustment and
reconciliation as provided in paragraph 5(b) of this lease, the sum of Nineteen
Thousand Five Hundred Twenty-Four and 11/100 Dollars ($19,524.11) on or before
the first day of the first full calendar month of the term and on the first day
of each and every successive calendar month, said sum representing Tenant's
estimated payment of its proportionate share of direct expenses as provided for
in paragraph 5(b) of this lease. Payment for direct expenses for any partial
month shall be payable in advance and shall be prorated based on the actual
number of days during the lease term occurring in such month divided by the
total number of days in such month.

                  (c) MANNER AND PLACE OF PAYMENT. All payments of basic rent
and direct expenses shall be paid to Landlord, without deduction or offset, in
lawful money of the United States of America, c/o McCandless Management
Corporation at 3945 Freedom Circle, Suite 640, Santa Clara, California 95054, or
to such other person or place as Landlord may from time to time designate in
writing.

                  (d) FIRST MONTH'S RENT. Concurrently with Tenant's execution
of this Lease, Tenant shall deposit with Landlord the sum of Ninety-Nine
Thousand Seventy-Six and 76/100 Dollars ($99,076.76) to be applied against the
basic rent and direct expenses for the first lease month of the term.

                  (e) SECURITY DEPOSIT.Concurrently with Tenant's execution of
this lease, Tenant shall deposit with Landlord the sum of Four Hundred Thousand
Dollars ($400,000), which sum shall be held by Landlord as a security deposit
for the faithful performance by Tenant of all of the terms, covenants and
conditions of this lease to be kept and performed by Tenant. Provided that
Tenant has not been in default under this lease at any time, the amount of the
security deposit required hereunder shall be reduced in accordance with the
following schedule:

                           Lease months 1-24                  $400,000
                           Lease months 25-36                 $300,000
                           Lease months 37-48                 $200,000
                           Lease months 49-60                 $100,000

                      If Tenant defaults with respect to any provision of
this lease,  including but not limited to the provisions relating to the
payment of basic rent and direct expenses, Landlord may (but shall not be
required to) use, apply or retain all or any part of this security deposit
for the payment of any amount which Landlord may spend by reason of Tenant's
default or to compensate Landlord for any other loss or damage which Landlord
may suffer by reason of Tenant's default. If any portion of said deposit is
so used, Tenant shall, within ten (10) days after written demand therefor,
deposit cash with Landlord in the amount sufficient to restore the security
deposit to its original amount; Tenant's failure to do so shall be a material
breach of this lease. Landlord shall not be required to keep this security
deposit separate from its general

<PAGE>

funds and Tenant shall not be entitled to interest on such deposit. If Tenant
is not in default at the expiration or termination of this lease, the
security deposit or any balance thereof shall be returned to Tenant after
Tenant has vacated the Premises. In the event of termination of Landlord's
interest in this lease, Landlord shall transfer said deposit to Landlord's
successor in interest, and Tenant agrees that Landlord shall thereupon be
released from liability for the return of such deposit or any accounting
therefor.

                  (f)  APPLICATION OF PAYMENTS.  All payments  received by
Landlord from Tenant may be applied by Landlord in Landlord's sole discretion
to the oldest payment obligation(s) owed by Tenant to Landlord or in such
other order as Landlord determines in Landlord's sole and absolute
discretion. No designation by Tenant, either in a separate writing or on a
check or money order, shall modify this clause or have any force or effect.
Notwithstanding the above, Landlord's determination not to apply such
payments to the oldest payment obligations first as specified above shall not
constitute a waiver by Landlord with respect to Landlord's claims against
Tenant for such prior payment obligation(s) of Tenant or Landlord's right to
apply future payments to such prior payment obligation(s) of Tenant in such
order as Landlord may determine in Landlord's sole and absolute discretion.

         5.       ADJUSTMENT OF BASIC RENT AND DIRECT EXPENSES

                  (a) ADJUSTMENTS TO BASIC RENT. The basic rent provided for in
paragraph 4(a) shall be adjusted periodically and the monthly basic rent for
each period shall be as set forth below:

                  Lease Months  1  - 12     $79,552.65 per month
                  Lease Months  13 - 24     $82,734.76 per month
                  Lease Months  25 - 36     $86,044.15 per month
                  Lease Months  37 - 48     $89,485.91 per month
                  Lease Months  49 - 60     $93,065.35 per month.

                  (b) ADJUSTMENTS TO DIRECT EXPENSES. Tenant's proportionate
share of direct expenses of the Project shall be sixteen and seventy-eight
one-hundredths percent (16.78%).

                  Tenant shall be required to pay to Landlord, as additional
rent in accordance with paragraph 4(b) of this lease, Tenant's proportionate
share of direct expenses for each calendar year (or portion thereof) during the
term of this lease. Tenant's estimated share of the monthly direct expenses
payable by Tenant during the calendar year in which the term commences is set
forth in paragraph 4(b) of this lease. A written estimate of Tenant's monthly
share of direct expenses for each succeeding calendar year shall be delivered to
Tenant prior to the commencement of each such succeeding calendar year (or as
soon as practicable thereafter). Tenant shall pay to Landlord in accordance with
paragraph 4(b) of this lease its monthly share of direct expenses as estimated
by Landlord. Landlord reserves the right to revise such written

<PAGE>

estimate during a calendar year if Landlord's actual or projected direct
expenses shows an increase or decrease in excess of ten percent (10%) from
that of an earlier written estimate delivered to Tenant, and if Landlord
elects to revise the earlier estimate, Landlord shall deliver the revised
estimate to Tenant, together with an explanation of the reasons therefor, and
Tenant shall revise its payments accordingly. Statements of the actual direct
expenses for the calendar year in which the term commences and for each
succeeding calendar year (herein called "statement of actual direct
expenses") shall be delivered to Tenant within one hundred twenty (120) days
following the expiration of each such calendar year (or as soon as
practicable thereafter). If the statement of actual direct expenses for any
such calendar year shows that Tenant's proportionate share of actual direct
expenses for the year is in excess of the aggregate amount Tenant has paid as
direct expenses for that calendar year, Tenant shall pay such excess to
Landlord within ten (10) days after receipt of the statement of actual direct
expenses. If Tenant fails to pay such excess amount due within said ten (10)
day period, Tenant shall pay an additional ten percent (10%) of the amount
due as a penalty. In the event that any statement of actual direct expenses
shall show that Tenant has paid Landlord an aggregate amount in excess of the
actual direct expenses for the preceding calendar year and Tenant is not in
default in the performance or observance of any of the terms, covenants or
conditions of this lease at the time such statement of actual direct expenses
is delivered, Landlord shall, at its option, promptly either refund such
excess to Tenant or credit the amount thereof to the monthly direct expenses
next becoming due from Tenant. The respective obligations of Landlord and
Tenant under this paragraph shall survive the expiration or other termination
of this lease.

                  As used in this lease, "direct expenses" shall include, but
not be limited to, (i) real property taxes, assessments, and other costs
identified as direct expenses in paragraph 13, (ii) insurance premiums and other
costs identified as direct expenses in paragraph 11, (iii) the cost of all
utilities and services including water, gas and sewer charges, electricity,
heat, air conditioning, refuse collection, and janitorial services identified as
direct expenses in paragraph 12, (iv) the costs of operating and maintaining the
Common Area identified as direct expenses in paragraph 15, including, but not
limited to, the landscaping, elevators, parking lots, paving, sidewalks,
showers, and security and exterminator services, (v) the costs and expenses of
maintaining and repairing the Project identified as direct expenses in paragraph
9, including, but not limited to mechanical, electrical, plumbing and sewage
systems, windows, glazing, gutters, downspouts, heating and ventilating and air
conditioning systems, walls, floorcoverings, roofs, structural elements,
exterior walls and the cost of maintenance contracts and supplies, materials,
equipment and tools used in connection therewith, (vi) the cost of certain
alterations identified as direct expenses in paragraph 8, (vii) amortization of
such capital improvements having a useful life greater than one year as Landlord
may have installed for the purpose of reducing operating costs and/or to comply
with all laws, rules and regulations of federal, state, county, municipal and
other governmental authorities now or hereafter in effect (the cost of such
capital improvement shall be amortized over its useful life, including interest
at the rate of 2% over the then current Prime Rate as published by the Wall
Street Journal on the date

<PAGE>

nearest to the date that such cost is incurred, and the monthly amortized
cost thereof shall be included in direct expenses), (viii) wages, salaries,
employee benefits (including union benefits) and related expenses of all
on-site and off-site personnel engaged in the operation and maintenance of
the Project (or the building in which the Premises are located) and payroll
taxes applicable thereto and all costs incurred to maintain a management
office in or near the Project (including, without limitation, rental payments
therefor or the reasonable rental value of the space so occupied), (ix)
supplies, materials, equipment and tools used or required in connection with
the operation and maintenance of the Project, (x) licenses, permits and
inspection fees, (xi) a reasonable reserve for repairs and replacement of
equipment used in the maintenance and operation of the Project, and (xii) all
other operating costs incurred by Landlord in maintaining and operating the
Project.

         6.       RESTRICTION ON USE

                  Tenant shall not do or permit to be done in or about the
Premises or the Project, nor bring or keep or permit to be brought or kept in or
about the Premises or Project, anything which is prohibited by or will in any
way increase the existing rate of, or otherwise affect, fire or any other
insurance covering the Project or any part thereof, or any of its contents, or
will cause a cancellation of any insurance covering the Project or any part
thereof, or any of its contents. Tenant shall not do or permit to be done
anything in or about the Premises or the Project which will constitute waste or
which will in any way obstruct or interfere with the rights of other tenants or
occupants of the Project or injure or annoy them, or use or allow the Premises
to be used for any unlawful purpose, nor shall Tenant cause, maintain or permit
any nuisance in or about the Premises or the Project. No loudspeaker or other
device, system or apparatus which can be heard outside the Premises shall be
used in or at the Premises without the prior written consent of Landlord. Tenant
shall not use the Premises for sleeping, washing clothes, cooking or in any
manner that will cause or emit any objectionable odor, noise or light into the
adjoining premises or Common Area. Tenant shall not do anything on the Premises
that will cause damage to the Project and Tenant shall not overload the floor
capacity of the Premises or the Project. No machinery, apparatus or other
appliance shall be used or operated in or on the Premises that will in any
manner injure, vibrate or shake the Premises. Landlord shall be the sole judge
of whether such odor, noise, light or vibration is such as to violate the
provisions of this paragraph 6. No waste materials or refuse shall be dumped
upon or permitted to remain upon any part of the Premises or the Project except
in trash containers placed inside exterior enclosures designated for that
purpose by Landlord, or where otherwise designated by Landlord; and no toxic or
hazardous materials shall be disposed of through the plumbing or sewage system.
No materials, supplies, equipment, finished products or semi-finished products,
raw materials or articles of any nature shall be stored or permitted to remain
outside of the building proper. No retail sales shall be made on the Premises.

         7.       COMPLIANCE WITH LAWS

<PAGE>

                  Tenant shall, in connection with its use and occupation of
the Premises, at its sole cost and expense, promptly observe and comply with
(i) all laws, statutes, ordinances and governmental rules, regulations and
requirements of federal, state, county, municipal and other governmental
authorities, now or hereafter in effect, which shall impose any duty on
Landlord or Tenant with respect to the use, occupancy or alteration of the
Premises, (ii) with the requirements of any board of fire underwriters or
other similar body now or hereafter constituted and (iii) with any direction
or occupancy certificate issued pursuant to law by any public authority;
provided, however, that no such failure shall be deemed a breach of these
provisions if Tenant, immediately upon notification, commences to remedy or
rectify said failure. The judgment of any court of competent jurisdiction or
the admission of Tenant in any action against Tenant (whether or not Landlord
is a party thereto), that Tenant has violated any such law, statute,
ordinance or governmental rule, regulation, requirement, direction or
provision, shall be conclusive of that fact as between Landlord and Tenant.
This lease shall remain in full force and effect notwithstanding any loss of
use or other effect on Tenant's enjoyment of the Premises by reason of any
governmental laws, statutes, ordinances, rules, regulations and requirements
now or hereafter in effect. Tenant shall comply with any covenant, condition
or restriction ("C.C.& R.'s") affecting the Premises.

         8.       ALTERATIONS

                  Tenant shall not make or suffer to be made any alteration,
addition or improvement to or of the Premises or any part thereof (collectively
referred to herein as "alterations") without (i) the prior written consent of
Landlord, (ii) a valid building permit issued by the appropriate governmental
authority and (iii) otherwise complying with all applicable laws, regulations
and requirements of governmental agencies having jurisdiction and with the
rules, regulations and requirements of any board of fire underwriters or similar
body. Notwithstanding the foregoing, Tenant may make non-structural alterations
costing in the aggregate less than $10,000 in any one lease year of the term
without the prior written consent of Landlord, provided that prior to making
such alteration Tenant informs Landlord in writing of the nature of the
alteration, the cost thereof and the contractor engaged or proposed to be
engaged to perform such work, and provided further that all such work complies
with clauses (ii) and (iii) above. Landlord's consent to any requested
alteration shall not create on the part of Landlord or cause Landlord to incur
any responsibility or liability for such alteration's compliance with all laws,
rules and regulations of federal, state, county, municipal and other
governmental authorities. Any alteration made by Tenant (excluding moveable
furniture and trade fixtures not attached to the Premises) shall at once become
a part of the Premises and belong to Landlord. Without limiting the foregoing,
all heating, lighting, electrical (including all wiring, conduit, outlets,
drops, buss ducts, main and subpanels), air conditioning, partitioning, drapery,
window covering and carpet installations made by Tenant, regardless of how
attached to the Premises, together with all other alterations that have become
an integral part of the Project in which the Premises are a part, shall be and
become part of the Premises and belong to Landlord upon installation and shall
not be deemed trade fixtures and, subject to Landlord's right to require removal
and

<PAGE>

restoration as specified herein, shall remain upon and be surrendered with
the Premises at the termination of the lease.

                  Regardless of whether Landlord's consent is required in
connection with the making of any alteration by Tenant, if Landlord consents
to the making of any alteration by Tenant, the same shall be made by Tenant
at its sole risk, cost and expense and only after Landlord's written approval
of any contractor or person selected by Tenant for that purpose, and the same
shall be made at such time and in such manner as Landlord may from time to
time designate. Tenant shall, if required by Landlord, secure at Tenant's
cost a completion and lien indemnity bond for such work. Upon the expiration
or sooner termination of the term, Landlord may, at its sole option, require
Tenant, at Tenant's sole cost and expense, to promptly remove any such
alteration made by Tenant and designated by Landlord to be removed, repair
any damage to the Premises caused by such removal and restore the Premises to
their condition prior to Tenant's alteration. Any moveable furniture and
equipment or trade fixtures remaining on the Premises at the expiration or
other termination of the term shall become the property of the Landlord;
provided, however, in addition to all other remedies available to Landlord at
law or in equity, Landlord may (i) require Tenant to remove same or (ii)
remove same at Tenant's cost, and Tenant shall be liable to Landlord for all
damages incurred by Landlord related thereto.

                  If during the term any alteration, addition or change of
the Premises is required by law, regulation, ordinance or order of any public
authority, Tenant, at its sole cost and expense, shall promptly make the
same. If during the term any alterations, additions or changes to the Common
Area or to the Project or building in which the Premises is located is
required by law, regulation, ordinance or order of any public or quasi-public
authority, and, in Landlord's judgment, it is impracticable for the tenants
of the Project to individually make such alterations, additions or changes,
Landlord shall make such alterations, additions or changes and the cost
thereof shall be a direct expenses charge and Tenant shall pay its percentage
share of said costs to Landlord as provided in paragraphs 4 and 5.

         9.       REPAIR AND MAINTENANCE

                  Subject to paragraph 16, Landlord shall maintain and keep
in good repair the Common Area and the mechanical, electrical, plumbing and
sewage systems, windows, window frames, plate glass, glazing, elevators,
gutters and downspouts, the roof, exterior walls, structural elements and the
heating, ventilating and air conditioning systems (excepting special air
conditioning of Tenant's computer room(s) as set forth below) of the Premises
and the Project; provided, however, that Landlord shall not be required to
perform repairs made necessary by the negligence or abuse of such
improvements or property by Tenant or its employees, agents, subtenants or
permitees. The cost of all maintenance and repairs made by Landlord pursuant
to this paragraph 9, including without limitation maintenance contracts and
supplies, materials, equipment and tools used in such repairs and
maintenance, shall be direct expenses and Tenant

<PAGE>

shall pay its percentage share of such costs to Landlord as provided in
paragraphs 4 and 5.

                  By entry hereunder Tenant accepts the Premises as being in
good and sanitary order, condition and repair (excepting only punchlist items).
Subject to paragraphs 16 and 21, and excepting repairs and maintenance required
by this paragraph 9 to be made by Landlord, Tenant at its cost shall keep the
Premises and every part thereof in good and sanitary order, condition and repair
and Tenant shall be solely responsible for the cost and maintenance of, and
electricity supplied to, any special air conditioning for Tenant's computer
facilities. Further, Tenant shall repair (or, at the option of Landlord,
reimburse Landlord if Landlord elects to repair) damage to improvements or other
property located on or about the Project where such repairs are made necessary
by the negligence of or abuse of such improvement or other property by Tenant or
its employees, agents, subtenants or permitees. Tenant waives all rights and
benefits under California Civil Code Sections 1932(1), 1941, and 1942 and under
any similar law, statute or ordinance now or hereafter in effect.

         10.      LIENS

                  Tenant shall keep the Premises and the Project free from
any liens arising out of any work performed, materials furnished or
obligations incurred by Tenant, its agents, employees or contractors. Upon
Tenant's receipt of a preliminary twenty (20) day notice filed by a claimant
pursuant to California Civil Code Section 3097, Tenant shall immediately
provide Landlord with a copy of such notice. Should any lien be recorded
against the Project, Tenant shall give immediate notice of such lien to
Landlord. In the event that Tenant shall not, within ten (10) days following
the imposition of such lien, cause the same to be released of record,
Landlord shall have, in addition to all other remedies provided herein and by
law, the right, but no obligation, to cause the same to be released by such
means as it shall deem proper, including payment of the claim giving rise to
such lien. All sums paid by Landlord for such, and all expenses (including
attorneys' fees) incurred by it in connection therewith, shall be payable to
Landlord by Tenant on demand with interest at the rate of eighteen percent
(18%) per annum or the maximum rate permitted by law, whichever is less.
Landlord shall have the right at all times to post and keep posted on the
Premises any notices permitted or required by law, or which Landlord shall
deem proper for the protection of Landlord, the Premises and the Project and
any other party having an interest therein, from mechanics' and materialmen's
liens and like liens. Tenant shall give Landlord at least fifteen (15) days'
prior notice of the date of commencement of any construction on the Premises
in order to permit the posting of such notices. In the event Tenant is
required to post an improvement bond with a public agency in connection with
any work performed by Tenant on or to the Premises, Tenant shall include
Landlord as an additional obligee.

         11.      INSURANCE

<PAGE>

                  Tenant, at its sole cost and expense, shall keep in force
during the term (i) commercial general liability and property damage
insurance with a combined single limit of at least $2,000,000 per occurrence
insuring against personal or bodily injury to or death of persons occurring
in, on or about the Premises or Project and any and all liability of the
insureds with respect to the Premises or arising out of Tenant's maintenance,
use or occupancy of the Premises and all areas appurtenant thereto, (ii)
direct physical loss-special insurance covering the leasehold improvements in
the Premises and all of Tenant's equipment, trade fixtures, appliances,
furniture, furnishings, and personal property from time to time located in,
on or about the Premises, with coverage in the amount of the full replacement
cost thereof, and (iii) Worker's Compensation Insurance as required by law,
together with employer's liability coverage with a limit of not less than
$1,000,000 for bodily injury for each accident and for bodily injury by
disease for each employee. Tenant's commercial general liability and property
damage insurance and Tenant's Workers Compensation Insurance shall be
endorsed to provide that said insurance shall not be cancelled or reduced
except upon at least thirty (30) days prior written notice to Landlord.
Further, Tenant's commercial general liability and property damage insurance
shall be primary and shall be endorsed to provide that Landlord and
McCandless Management Corporation (or other property management company
designated by Landlord) and their respective partners, officers, directors
and employees and such other persons or entities as directed from time to
time by Landlord shall be named as additional insureds for all liability
using ISO Bureau Form CG20111185 (or a successor form) or such other
endorsement form reasonably acceptable to Landlord; shall contain a
severability of interest clause and a cross-liability endorsement; shall be
endorsed to provide that the limits and aggregates apply per location using
ISO Bureau Form CG25041185 (or a successor form) or such other endorsement
form reasonably acceptable to Landlord; and shall be issued by an insurance
company admitted to transact business in the State of California and rated
A+VIII or better in Best's Insurance Reports (or successor report). The
deductibles for all insurance required to be maintained by Tenant hereunder
shall be satisfactory to Landlord. The commercial general liability insurance
carried by Tenant shall specifically insure the performance by Tenant of the
indemnification provisions set forth in paragraph 17 of this lease provided,
however, nothing contained in this paragraph 11 shall be construed to limit
the liability of Tenant under the indemnification provisions set forth in
said paragraph 17. If Landlord or any of the additional insureds named on any
of Tenant's insurance, have other insurance which is applicable to the
covered loss on a contributing, excess or contingent basis, the amount of the
Tenant's insurance company's liability under the policy of insurance
maintained by Tenant shall not be reduced by the existence of such other
insurance. Any insurance carried by Landlord or any of the additional
insureds named on Tenant's insurance policies shall be excess and
non-contributing with the insurance so provided by Tenant.

                  Tenant shall, prior to the commencement of the term and at
least thirty (30) days prior to any renewal date of any insurance policies
required to be maintained by Tenant pursuant to this paragraph, provide
Landlord with a completed Certificate of

<PAGE>

Insurance, using a form acceptable in Landlord's reasonable judgement,
attaching thereto copies of all endorsements required to be provided by
Tenant under this lease. Tenant agrees to increase the coverage or otherwise
comply with changes in connection with said commercial general liability,
property damage, direct physical loss and Worker's Compensation Insurance as
Landlord or Landlord's lender may from time to time require.

                  Landlord shall obtain and keep in force a policy or
policies of insurance covering loss or damage to the Premises and Project, in
the amount of the full replacement value thereof, providing protection
against those perils included within the classification of "all risk"
insurance, with increased cost of reconstruction and contingent liability
(including demolition), plus a policy of rental income insurance in the
amount of one hundred percent (100%) of twelve (12) months' rent (including
sums paid as additional rent) and such other insurance as Landlord or
Landlord's lender may from time to time require. Landlord may, but shall not
be obligated to, obtain flood and/or earthquake insurance. Landlord shall
have no liability to Tenant if Landlord elects not to obtain flood and/or
earthquake insurance. The cost of all such insurance purchased by Landlord,
plus any charges for deferred payment of premiums and the amount of any
deductible incurred upon any covered loss within the Project, shall be direct
expenses and Tenant shall pay to Landlord its percentage share of such costs
as provided in paragraphs 4(b) and 5(b). If the cost of insurance is
increased due to Tenant's use of the Premises, then Tenant shall pay to
Landlord upon demand the full cost of such increase.

                  Landlord and Tenant hereby mutually waive any and all
rights of recovery against one another for real or personal property loss or
damage occurring to the Premises or the Project, or any part thereof, or to
any personal property therein, from perils insured against under fire and
extended insurance and any other property insurance policies existing for the
benefit of the respective parties so long as such insurance permits waiver of
liability and contains a waiver of subrogation without additional premiums.

                  If Tenant does not take out and maintain insurance as
required pursuant to this paragraph 11, Landlord may, but shall not be
obligated to, take out the necessary insurance and pay the premium therefor,
and Tenant shall repay to Landlord promptly on demand, as additional rent,
the amount so paid. In addition, Landlord may recover from Tenant and Tenant
agrees to pay, as additional rent, any and all reasonable expenses (including
attorney fees) and damages which Landlord may sustain by reason of the
failure of Tenant to obtain and maintain such insurance, it being expressly
declared that the expenses and damages of Landlord shall not be limited to
the amount of the premiums thereon.

         12.      UTILITIES AND SERVICE

                  Landlord shall furnish to the Premises and to the Project,
during reasonable hours of generally recognized business days, to be
determined by Landlord,

<PAGE>

and subject to the rules and regulations of the Project, reasonable
quantities of water, gas and electricity suitable for the intended use of the
Premises and the Project, heat and air conditioning required in Landlord's
judgment for the comfortable use and occupation of the Premises and the
Project, refuse collection and janitorial services. Heating and air
conditioning shall be made available to the Premises at all times, provided
that Tenant shall be charged the reasonable cost for providing such service
after normal business hours as reasonably determined by Landlord, which cost
is currently $35 per hour and such charges shall be deemed additional rent
hereunder and due and payable upon demand. Tenant agrees that at all times it
will cooperate fully with Landlord and abide by all regulations and
requirements that Landlord may prescribe for the proper functioning and
protection of the heating, ventilating and air conditioning systems. The cost
of all utilities and services furnished by Landlord to the Premises and to
the Project shall be direct expenses and Tenant shall pay its percentage
share of such costs to Landlord as provided in paragraphs 4 and 5.

                  Landlord shall not be liable for, and Tenant shall not be
entitled to any abatement or reduction of rent by reason of, Landlord's
failure to furnish any of the foregoing services when such failure is caused
by accident, breakage, repairs, strikes, lockouts or other labor disturbances
or labor disputes of any character, governmental moratoriums, regulations or
other governmental actions, or by any other cause, similar or dissimilar,
beyond the reasonable control of Landlord. In addition, Tenant shall not be
relieved from the performance of any covenant or agreement in this lease
because of any such failure, and no eviction of Tenant shall result from such
failure.

                  Tenant will not, without the written consent of Landlord,
use any apparatus or device in the Premises (including, without limitation,
electronic data processing machines, punch card machines or machines using
current in excess of 110 volts) which will in any way increase the amount of
electricity, water or air conditioning usually furnished or supplied to
premises in the Project being used as general office space, or connect with
electric current (except through existing electrical outlets in the Premises)
or with water pipes any apparatus or device for the purpose of using electric
current or water. If Tenant shall require water or electric current in excess
of that usually furnished or supplied to premises in the Project being used
as general office space, then Tenant shall first obtain the written consent
of Landlord, which consent shall not be unreasonably withheld, and Tenant
shall pay to Landlord promptly on demand, as additional rent, the full cost
of such excess use. Landlord may cause an electric current or water meter to
be installed in the Premises in order to measure the amount of electric
current or water consumed for any such excess use. The cost of any such meter
and of the installation, maintenance and repair thereof, and all charges for
such excess water and electric current consumed (as shown by meters and at
the rates then charged by the furnishing public utility) plus any additional
expense incurred by Landlord in keeping account of electric current or water
so consumed, shall be paid by Tenant, and Tenant agrees to pay Landlord
therefor promptly upon demand by Landlord. Whenever heat generating machines
or equipment are used in the Premises by Tenant which affect the temperature
otherwise maintained by the air conditioning system, Landlord shall have the
right to install supplementary air conditioning units in

<PAGE>

the Premises and the cost thereof, including the cost of installation and the
cost of operation and maintenance thereof, shall be paid by Tenant to
Landlord upon demand by Landlord as additional rent.

                  Landlord acknowledges that Tenant will operate a modest
Server Facility that will be run on a 24 hour, 7 day per week basis and any
alterations required to be made to the Premises in connection with such
facility shall be subject to Landlord's consent and the requirements of
paragraph 8 of this lease. HVAC to the Server Facility will be supplementary.
Tenant shall be solely responsible for all maintenance and repair costs
related to the Server Facility and any equipment installed therein. Tenant
shall pay to Landlord the reasonable cost of the excess electricity used for
the Server Facility as reasonably determined by Landlord.

         13.      TAXES AND OTHER CHARGES

                  All real estate taxes and assessments and other taxes, fees
and charges of every kind or nature, foreseen or unforeseen, which are
levied, assessed or imposed upon Landlord and/ or against the Premises,
building, Common Area or Project or any part thereof by any federal, state,
county, regional, municipal or other governmental or quasi-governmental or
special district authority, together with any increases therein whether
resulting from increased rate and/or valuation, shall be a direct expense and
Tenant shall pay its percentage share of such costs to Landlord as provided
in paragraphs 4 and 5. By way of illustration and not limitation, "other
taxes, fees and charges" as used herein include any and all taxes payable by
Landlord (other than state and federal personal or corporate income taxes
measured by the net income of Landlord from all sources, premium taxes and
Landlord's franchise, estate, inheritance and gift taxes), whether or not now
customary or within the contemplation of the parties hereto, (i) upon,
allocable to, or measured by the rent payable hereunder, including, without
limitation, any gross income or excise tax levied by the local, state or
federal government with respect to the receipt of such rent, (ii) upon or
with respect to the possession, leasing, operation, management, maintenance,
alteration, repair, use or occupancy by Tenant of the Premises or any part
thereof, (iii) upon or measured by the value of Tenant's personal property or
leasehold improvements located in the Premises, (iv) upon this transaction or
any document to which Tenant is a party creating or transferring an interest
or estate in the Premises, (v) upon or with respect to vehicles, parking or
the number of persons employed on or about the Project, and (vi) any tax,
license, franchise fee or other imposition upon Landlord which is otherwise
measured by or based in whole or in part upon the Project or any portion
thereof. If Landlord contests any such tax, fee or charge, the cost and
expense incurred by Landlord thereby (including, but not limited to, costs of
attorneys and experts) shall also be direct expenses and Tenant shall pay its
percentage share of such costs to Landlord as provided in paragraphs 4 and 5.
In the event the Premises and any improvements installed therein by Tenant or
Landlord are valued by the assessor disproportionately higher than those of
other tenants in the building or Project or in the event alterations or
improvements are made to the Premises, Tenant's percentage share of such
taxes, assessments, fees and/or charges shall be readjusted upward
accordingly and Tenant

<PAGE>

agrees to pay such readjusted share. Such determination shall be made by
Landlord from the respective valuations assigned in the assessor's work sheet
or such other information as may be reasonably available and Landlord's
determination thereof shall be conclusive.

                  Tenant agrees to pay, before delinquency, any and all taxes
levied or assessed during the term hereof upon Tenant's equipment, furniture,
fixtures and other personal property located in the Premises, including
carpeting and other property installed by Tenant notwithstanding that such
carpeting or other property has become a part of the Premises. If any of
Tenant's personal property shall be assessed with the Project, Tenant shall
pay to Landlord, as additional rent, the amounts attributable to Tenant's
personal property within ten (10) days after receipt of a written statement
from Landlord setting forth the amount of such taxes, assessments and public
charges attributable to Tenant's personal property.

         14.      ENTRY BY LANDLORD

                  Landlord reserves, and shall at all reasonable times have,
the right to enter the Premises (i) to inspect the Premises, (ii) to supply
services to be provided by Landlord hereunder, (iii) to show the Premises to
prospective purchasers, lenders or tenants and to put 'for sale' or 'for
lease' signs thereon, (iv) to post notices required or allowed by this lease
or by law, (v) to alter, improve or repair the Premises and any portion of
the Project, and (vi) to erect scaffolding and other necessary structures in
or through the Premises or the Project where reasonably required by the
character of the work to be performed. Landlord shall not be liable in any
manner for any inconvenience, disturbance, loss of business, nuisance or
other damage arising from Landlord's entry and acts pursuant to this
paragraph 14 and Tenant shall not be entitled to an abatement or reduction of
rent if Landlord exercises any rights reserved in this paragraph 14. For each
of the foregoing purposes, Landlord shall at all times have and retain a key
with which to unlock all of the doors in, on and about the Premises
(excluding Tenant's vaults, safes and similar areas designated in writing by
Tenant in advance), and Landlord shall have the right to use any and all
means which Landlord may deem proper to open said doors in an emergency in
order to obtain entry to the Premises. Any entry by Landlord to the Premises
pursuant to this paragraph 14 shall not under any circumstances be construed
or deemed to be a forcible or unlawful entry into or a detainer of the
Premises or an eviction, actual or constructive, of Tenant from the Premises
or any portion thereof.

         15.      COMMON AREA; PARKING

                  Subject to the terms and conditions of this lease and such
rules and regulations as Landlord may from time to time prescribe, Tenant and
Tenant's employees and invitees shall, in common with other occupants of the
Project, and their respective employees and invitees and others entitled to
the use thereof, have the

<PAGE>

nonexclusive right to use those areas of the Common Area designated by
Landlord for the general use and convenience of the occupants of the Project
(which areas and facilities shall include, but not be limited to, common
lobbies, corridors, restrooms and showers; telephone, electrical, janitorial
and mechanical rooms; elevators, stairwells, vertical duct shafts; sidewalks;
parking, refuse, landscape and plaza areas; roofs; building exteriors;
electrical, mechanical, plumbing and HVAC systems; and storage areas), which
areas and facilities are referred to herein as "Common Area". This right
shall terminate upon the termination of this lease.

                  Landlord reserves the right from time to time to make
changes in the shape, size, location, amount and extent of the Common Area.
Landlord shall also have the right at any time to change the name, number or
designation by which the Project is commonly known. Landlord further reserves
the right to promulgate such rules and regulations relating to the use of the
Common Area, and any part thereof, as Landlord may deem appropriate for the
best interests of the occupants of the Project. The rules and regulations
shall be binding upon Tenant upon delivery of a copy of them to Tenant and
Tenant shall abide by them and cooperate in their observance. Such rules and
regulations may be amended by Landlord from time to time, with or without
advance notice.

                  Tenant shall have the nonexclusive use of one hundred five
(105) parking spaces in the Common Area as designated from time to time by
Landlord. Landlord reserves the right at its sole option to assign and label
parking spaces, but it is specifically agreed that Landlord is not
responsible for policing any such parking spaces. Tenant shall not at any
time park or permit the parking of Tenant's trucks or other vehicles, or the
trucks or other vehicles of others, adjacent to loading areas so as to
interfere in any way with the use of such areas; nor shall Tenant at any time
park or permit the parking of Tenant's vehicles or trucks, or the vehicles or
trucks of Tenant's suppliers or others, in any portion of the Common Area not
designated by Landlord for such use by Tenant. Tenant shall not park or
permit any inoperative vehicle or equipment to be parked on any portion of
the Common Area.

                  Landlord shall operate, manage and maintain the Common
Area. The manner in which the Common Area shall be operated, managed and
maintained and the expenditures for such operation, management and
maintenance shall be at the sole discretion of Landlord. The cost of such
maintenance, operation and management of the Common Area, together with the
costs of security and exterminator services and salaries and employee
benefits (including union benefits) of on-site and accounting personnel
engaged in such maintenance and operations management, shall be a direct
expense and Tenant shall pay to Landlord its percentage share of such costs
as provided in paragraphs 4 and 5.

         16.      DAMAGE BY FIRE; CASUALTY

                  In the event the Premises are damaged by any casualty which
is covered under an insurance policy required to be maintained by Landlord
pursuant to paragraph

<PAGE>

11, Landlord shall be entitled to the use of all insurance proceeds and shall
repair such damage as soon as reasonably possible and this lease shall
continue in full force and effect.

                  In the event the Premises are damaged by any casualty not
covered under an insurance policy required to be maintained pursuant to
paragraph 11, Landlord may, at Landlord's option, either (i) repair such
damage, at Landlord's expense, as soon as reasonably possible, in which event
this lease shall continue in full force and effect, or (ii) give written
notice to Tenant within thirty (30) days after the date of the occurrence of
such damages of Landlord's intention to cancel and terminate this lease as of
the date of the occurrence of the damages; provided, however, that if such
damage is caused by an act or omission of Tenant or its agent, servants or
employees, then Tenant shall repair such damage promptly at its sole cost and
expense. In the event Landlord elects to terminate this lease pursuant
hereto, Tenant shall have the right within ten (10) days after receipt of the
required notice to notify Landlord in writing of Tenant's intention to repair
such damage at Tenant's expense, without reimbursement from Landlord, in
which event this lease shall continue in full force and effect and Tenant
shall proceed to make such repairs as soon as reasonably possible. If Tenant
does not give such notice within the ten (10) day period, this lease shall be
cancelled and terminated as of the date of the occurrence of such damage.
Under no circumstances shall Landlord be required to repair any injury or
damage to (by fire or other cause), or to make any restoration or replacement
of, any of Tenant's personal property, trade fixtures or property leased from
third parties, whether or not the same is attached to the Premises.

                  If the Premises are totally destroyed during the term from
any cause (including any destruction required by any authorized public
authority), whether or not covered by the insurance required under paragraph
11, this lease shall automatically terminate as of the date of such total
destruction; provided, however, that if the Premises can reasonably and
lawfully be repaired or restored within twelve (12) months of the date of
destruction to substantially the condition existing prior to such destruction
and if the proceeds of the insurance payable to the Landlord by reason of
such destruction are sufficient to pay the cost of such repair or
restoration, then the said insurance proceeds shall be so applied, Landlord
shall promptly repair and restore the Premises and this lease shall continue,
without interruption, in full force and effect. If the Premises are totally
destroyed during the last twelve (12) months of the term, Landlord may at
Landlord's option cancel and terminate this lease as of the date of
occurrence of such damage by giving written notice to Tenant of Landlord's
election to do so within thirty (30) days after the occurrence of such damage.

                  If the Premises are partially or totally destroyed or
damaged and Landlord or Tenant repair them pursuant to this lease, the rent
payable hereunder for the period during which such damage and repair
continues shall be abated only to the extent that Landlord received proceeds
from any policy of rental income insurance. Tenant shall have no claim
against Landlord for any damage, loss or expense suffered by reason of any
such damage, destruction, repair or restoration. The parties waive the
provisions of

<PAGE>

California Civil Code Sections 1932(2) and 1933(4) (which provisions permit
the termination of a lease upon destruction of the leased premises), and
hereby agree that the provisions of this paragraph 16 shall govern in the
event of such destruction.

         17.      INDEMNIFICATION

                  Landlord shall not be liable to Tenant and Tenant hereby
waives all claims against Landlord for any injury to or death of any person
or damage to or destruction of property in or about the Premises or the
Project by or from any cause whatsoever except the failure of Landlord to
perform its obligations under this lease where such failure has persisted for
an unreasonable period of time after notice of such failure. Without limiting
the foregoing, Landlord shall not be liable to Tenant for any injury to or
death of any person or damages to or destruction of property by reason of, or
arising from, any latent defect in the Premises or Project or the act or
negligence of any other tenant of the Project. Tenant shall immediately
notify Landlord of any defect in the Premises or Project.

                  Except as to injury to persons or damage to property the
principal cause of which is the failure by Landlord to observe any of the
terms and conditions of this lease, Tenant shall hold Landlord harmless from
and indemnify and defend Landlord against any claim, liability, loss, damage
or expense (including attorney fees) arising out of any injury to or death of
any person or damage to or destruction of property occurring in, on or about
the Premises from any cause whatsoever or on account of the use, condition,
occupational safety or occupancy of the Premises. Tenant shall further hold
Landlord harmless from and indemnify and defend Landlord against any claim,
liability, loss, damage or expense (including attorney fees) arising (i) from
Tenant's use of the Premises or from the conduct of its business or from any
activity or work done, permitted or suffered by Tenant or its agents or
employees in or about the Premises or Project, (ii) out of the failure of
Tenant to observe or comply with Tenant's obligation to observe and comply
with laws or other requirements as set forth in paragraph 7, (iii) by reason
of Tenant's use, handling, storage, or disposal of toxic or hazardous
materials or waste, (iv) by reason of any labor or service performed for, or
materials used by or furnished to, Tenant or any contractor engaged by Tenant
with respect to the Premises, or (v) from any other act, neglect, fault or
omission of Tenant or its agents or employees.

                  The provisions of this paragraph 17 shall survive the
expiration or earlier termination of this lease.

         18.      ASSIGNMENT AND SUBLETTING

                  Tenant shall not voluntarily assign, encumber or otherwise
transfer its interest in this lease or in the Premises, or sublease all or
any part of the Premises, or allow any other person or entity to occupy or
use all or any part of the Premises, without first obtaining Landlord's
written consent, which consent shall not be unreasonably withheld, and
otherwise complying with the requirements of this paragraph 18. Any

<PAGE>

assignment, encumbrance or sublease without Landlord's consent, shall
constitute a default. The proposed assignee or subtenant is referred to
herein as the "Transferee". Reasonable grounds for denying consent to a
proposed assignment or sublet include, without limitation, any of the
following:

                  (a)   Transferee's character, reputation, credit history,
or business is not consistent with the character or quality of the Project;

                  (b)   Transferee would be a significantly less prestigious
occupant of the Project than Tenant;

                  (c)   Transferee is either a government agency or an
instrumentality of one;

                  (d)   Transferee's intended use of the Premises is
inconsistent with the permitted use specified in this lease or will
materially and adversely affect Landlord's interest;

                  (e)   Transferee's financial condition is or may be
inadequate to support the lease obligations of Transferee under the
assignment or sublease;

                  (f)   The assignment or sublet would cause Landlord to
violate another lease or agreement to which Landlord is a party or would give
another tenant in the Project the right to cancel its lease;

                  (g)   Transferee occupies space in the Project and such
space is not contiguous to the Premises, is negotiating with Landlord to
lease space in the Project, or has negotiated with Landlord during the six
(6) months immediately preceding notice of the proposed assignment or sublet
to Landlord;

                  (h)   Transferee does not intend to occupy the entire
Premises and conduct business there for a substantial portion of the term of
the assignment or sublease; or

                  (i)   The rent charged by Tenant to Transferee during the
term of the assignment or sublet, using a present-value analysis, is less
than ninety-five percent (95%) of the rent then being quoted by Landlord for
comparable space in the Project for a comparable term, using a present-value
analysis.

                  If Tenant desires to sublet or assign all or any portion of
the Premises, Tenant shall give Landlord written notice ("Transfer Notice")
thereof, specifying the projected commencement date of the proposed sublet or
assignment (which date shall be not less than thirty (30) days or more than
ninety (90) days after the date of Landlord's receipt of such notice), the
portions of the Premises proposed to be sublet or assigned (the "Subject
Space"), a description of any planned alterations or improvements to the
Subject Space, the terms and conditions of the proposed

<PAGE>

assignment or sublease (including the rent to be paid by the Transferee and
any and all other consideration to be given by the Transferee), the name,
address and telephone number of the Transferee, and a detailed calculation of
the Transfer Premium (certified by Tenant's chief financial officer) to be
paid as provided below. Tenant shall further provide Landlord with such other
information concerning the Transferee as requested by Landlord. Landlord
shall have the right to communicate with the Transferee to discuss the terms
of the proposed assignment or sublet, to discuss and negotiate, if Landlord
desires, the terms of a direct lease between Landlord and Transferee, or any
other matter and to enter into a direct lease agreement with Transferee as
provided below and failure of Transferee to meet with Landlord and to
negotiate in good faith the terms of a direct lease with Landlord shall
constitute grounds for Landlord's refusal to consent to the proposed
assignment or sublet. For a period of thirty (30) days after Landlord's
receipt of the Transfer Notice, Landlord shall have the option ("Landlord's
Recapture Right"), exercisable by delivering written notice to Tenant, to
terminate this lease for the Subject Space or for the entire Premises as of
the date specified in Landlord's written notice to Tenant, which date shall
not be less than thirty (30) days nor more than ninety (90) days after the
date of Landlord's written notice to Tenant; provided, however, Landlord's
Recapture Right shall not apply to subleases which (i) are for space located
entirely within the area designated as the "Sublease Recapture Exemption
Space" as shown on Exhibit D attached hereto and (ii) have a term which
expires on or before the last day of the third lease year. If Landlord
exercises its option to terminate this lease as provided in the foregoing
sentence, Landlord may, if it so elects, enter into a new lease for the
Premises or any portion thereof with the Transferee or any other third party
on such terms as Landlord and the Transferee or other third party may agree;
in such event, Tenant shall not be entitled to any portion of the profit, if
any, which Landlord may realize on account of such termination and reletting.
If Landlord exercises its option to terminate this lease with respect to the
Subject Space only (i.e., less than the entire Premises), then Tenant shall
continue to be obligated under this lease as to the remaining space (i.e.,
the Premises less the Subject Space) and basic rent and direct expenses
payable by Tenant under this lease shall be adjusted as follows: (i) the
basic rent amount(s) specified in paragraphs 4(a) and 5(a) of this lease
shall be multiplied by a fraction, the numerator of which is the square feet
of the Premises retained by Tenant after Landlord's recapture of the Subject
Space and the denominator of which is the total square feet of the Premises
before Landlord's recapture; (ii) Tenant's proportionate share of direct
expenses as provided in paragraph 5(b) of this lease shall be reduced to
reflect Tenant's proportionate share based on the square feet of the Premises
retained by Tenant after Landlord's recapture. This lease as so amended shall
continue thereafter in full force and effect. Either party may require
written confirmation of the amendments to this lease necessitated by
Landlord's recapture of the Subject Space. If Landlord recaptures the Subject
Space, Landlord shall, at Landlord's sole expense, construct any partitions
required to segregate the Subject Space from the remaining Premises retained
by Tenant. Tenant shall, however, pay for painting, covering, or otherwise
decorating the surfaces of the partitions facing the remaining Premises
retained by Tenant.

<PAGE>

                  If Landlord does not elect to terminate this lease as
provided hereinabove in this paragraph 18 and if Landlord consents in writing
to the proposed assignment or sublet, Tenant shall be free to assign or
sublet all or a portion of the Premises subject to the following conditions:
(i) any assignment or sublease shall be on the same terms set forth in the
Transfer Notice given to Landlord; (ii) no assignment or sublease shall be
valid and no assignee or subtenant shall take possession of the Subject Space
until an executed counterpart of such assignment or sublease has been
delivered to Landlord; (iii) no assignee or subtenant shall have a further
right to assign or sublet; (iv) any sums or other consideration payable by
Transferee to Tenant as a result of or in connection with such assignment or
sublet (except rental or other payments received which are attributable to
the amortization over the term of this lease of (a) the cost of leasehold
improvements constructed by Tenant for such assignee or subtenant, excluding
the initial tenant improvements to be constructed in the Premises pursuant to
the terms of this lease, if any, and (b) broker fees paid by Tenant in
connection therewith) whether denominated rentals or otherwise, which exceed,
in the aggregate, the basic rent and direct expenses which Tenant is
obligated to pay Landlord under

<PAGE>

this lease during the term of such assignment or sublease (prorated to
reflect obligations allocable to that portion of the Premises subject to such
sublease), shall be payable to Landlord monthly as additional rent under this
lease without affecting or reducing any other obligation of Tenant hereunder
(such amounts are referred to herein as the "Transfer Premium"); (v) no
assignment or sublet shall release Tenant of Tenant's obligation or alter the
primary liability of Tenant to pay the rent and to perform all other
obligations to be performed by Tenant hereunder; and (vi) any assignee or
subtenant must expressly agree to assume and perform all of the covenants and
conditions of Tenant under this lease. Tenant shall pay to Landlord promptly
upon demand as additional rent, Landlord's actual attorneys' fees and other
costs incurred for reviewing, processing or documenting any requested
assignment or sublease, whether or not Landlord's consent is granted. Tenant
shall not be entitled to assign this lease or sublease all or any part of the
Premises (and any attempt to do so shall be voidable by Landlord) during any
period in which Tenant is in default under this lease.

                  If Tenant is a partnership, a withdrawal or change,
voluntary or involuntary or by operation of law, of any general partner or
the dissolution of the partnership shall be deemed an assignment of this
lease subject to all the conditions of this paragraph 18. If Tenant is a
corporation any dissolution, merger, consolidation or other reorganization of
Tenant or the sale or other transfer of a controlling percentage of the
capital stock of Tenant or the sale of more than fifty percent (50%) of the
value of Tenant's assets shall be an assignment of this lease subject to all
the conditions of this paragraph 18. The term "controlling percentage" means
the ownership of, and the right to vote, stock possessing more than 50% of
the total combined voting power of all classes of Tenant's capital stock
issued, outstanding and entitled to vote. This subparagraph of this paragraph
18 shall not apply if Tenant is a corporation the stock of which is traded on
the New York Stock Exchange, the American Stock Exchange or NASDAQ.

                  The acceptance of rent by Landlord from any other person
shall not be deemed to be a waiver by Landlord of any provision hereof.
Consent to one assignment or sublet shall not be deemed consent to any
subsequent assignment or sublet. In the event of default by any assignee of
Tenant or any successor of Tenant in the performance of any of the terms
hereof, Landlord may proceed directly against Tenant without the necessity of
exhausting remedies against such assignee or successor. Landlord may consent
to subsequent assignments or sublets of this lease or amendments or
modifications to this lease with assignees of Tenant, without notifying
Tenant, or any successor of Tenant, and without obtaining its or their
consent thereto and such action shall not relieve Tenant of liability under
this lease.

                  No interest of Tenant in this lease shall be assignable by
operation of law (including, without limitation, the transfer of this lease
by testacy or intestacy). Each of the following acts shall be considered an
involuntary assignment: (i) if Tenant is or becomes bankrupt or insolvent,
makes an assignment for the benefit of creditors or institutes a proceeding
under the Bankruptcy Act in which Tenant is the bankrupt; or, if Tenant is a
partnership or consists of more than one person or entity, if any partner of

<PAGE>

the partnership or other person or entity is or becomes bankrupt or
insolvent, or makes an assignment for the benefit of creditors; (ii) if a
writ of attachment or execution is levied on this lease; or (iii) if, in any
proceeding or action to which Tenant is a party, a receiver is appointed with
authority to take possession of the Premises. An involuntary assignment shall
constitute a default by Tenant and Landlord shall have the right to elect to
terminate this lease, in which case this lease shall not be treated as an
asset of Tenant.

                  Tenant immediately and irrevocably assigns to Landlord, as
security for Tenant's obligations under this lease, all rent or other
consideration from any assignment or subletting of all or a part of the
Premises as permitted by this lease, and Landlord, as assignee and as
attorney-in-fact for Tenant, or a receiver of Tenant appointed on Landlord's
application, may collect such rent or other consideration and apply it toward
Tenant's obligations under this lease and any Transferee agrees to make such
payments directly to Landlord upon Landlord's written request; provided that,
until the occurrence of a default by Tenant, Tenant shall have the right to
collect such rent, subject to promptly forwarding to Landlord any portion
thereof to which Landlord is entitled pursuant to this paragraph 18.

         19.      DEFAULT

                  The occurrence of any of the following shall constitute a
default by Tenant: (i) failure of Tenant to pay any rent or other sum payable
hereunder within five (5) days after the date that such payment becomes due;
(ii) abandonment of the Premises (Tenant's failure to occupy and conduct
business in the Premises for fourteen (14) consecutive days and Tenant is
otherwise in default under (i) above shall be deemed an abandonment); (iii)
failure of Tenant to deliver to Landlord any instrument, assurance, financial
statement, subordination agreement or certificate of estoppel required under
this Lease within the time period specified for such performance if the
failure continues for five (5) days after written notice of the failure from
Landlord to Tenant; or (iv) failure of Tenant to perform any other obligation
under this lease if the failure to perform is not cured within fifteen (15)
days after written notice thereof has been given to Tenant, except in the
case of an emergency or dangerous condition, in which case Tenant's time to
perform shall be that time period which is reasonable under the
circumstances, but not more than fifteen (15) days. The notice referred to in
clauses (iii) and (iv) above shall specify the obligations Tenant has failed
to perform. No notice shall be deemed a forfeiture or termination of this
lease unless Landlord so elects in the notice. No notice shall be required in
the event of abandonment or vacation of the Premises.

                  In addition to the above, the occurrence of any of the
following events shall also constitute a default by Tenant: (i) Tenant fails
to pay its debts as they become due or admits in writing its inability to pay
its debts, or makes a general assignment for the benefit of creditors (for
purposes of determining whether Tenant is not paying its debts as they become
due, a debt shall be deemed overdue upon the earliest to occur of the
following: thirty (30) days from the date a statement therefor has

<PAGE>

been rendered; the date on which any action or proceeding therefor is
commenced; or the date on which a formal notice of default or demand has been
sent); (ii) Tenant fails to furnish to Landlord a schedule of Tenant's aged
accounts payable within ten (10) days after Landlord's written request; (iii)
any financial statements given to Landlord by Tenant, any assignee of Tenant,
subtenant of Tenant, any guarantor of Tenant, or successor in interest of
Tenant (including, without limitation, any schedule of Tenant's aged accounts
payable) are materially false; or (iv) any financial statement or other
financial information furnished by Tenant pursuant to the provisions of this
lease or at the request of Landlord evidences that either Tenant's net worth
or its net assets are at least twenty-five percent (25%) less than the net
worth or net assets shown in either the immediately prior financial statement
or the financial statement of Tenant furnished at the time of execution of
this lease, and Tenant fails to furnish promptly to Landlord, after notice
from Landlord to Tenant, an additional security deposit in cash equivalent to
the aggregate of the basic rent and direct expenses (without regard to any
rent abatement) payable hereunder for the twelve (12) full calendar months
immediately preceding such notice. At any time during the term of this lease
Landlord, at Landlord's option, shall have the right to receive from Tenant,
upon Landlord's request, a current annual balance sheet for Landlord's
review. If the balance sheet shows a negative net worth, Landlord may
terminate this lease by giving Tenant sixty (60) days prior written notice.

                  In the event of a default by Tenant, then Landlord, in
addition to any other rights and remedies of Landlord at law or in equity,
shall have the right either to terminate Tenant's right to possession of the
Premises (and thereby terminate this lease) or, from time to time and without
termination of this lease to relet the Premises or any part thereof for the
account and in the name of Tenant for such term and on such terms and
conditions as Landlord in its sole discretion may deem advisable, with the
right to make alterations and repairs to the Premises.

                  Should Landlord elect to keep this lease in full force and
effect, Landlord shall have the right to enforce all of Landlord's rights and
remedies under this lease, including but not limited to the right to recover
and to relet the Premises and such other rights and remedies as Landlord may
have under California Civil Code Section 1951.4, which Section provides that
the landlord may continue the Lease in effect after the tenant's breach and
abandonment and recover rent as it becomes due, when the tenant has the right
to sublet or assign, subject only to reasonable limitations (or successor
Code section) or any other California statute. If Landlord relets the
Premises, then Tenant shall pay to Landlord, as soon as ascertained, the
costs and expenses incurred by Landlord in such reletting and in making
alterations and repairs. Rentals received by Landlord from such reletting
shall be applied (i) to the payment of any indebtedness due hereunder, other
than basic rent and direct expenses, from Tenant to Landlord, (ii) to the
payment of the cost of any repairs necessary to return the Premises to good
condition normal wear and tear excepted, including the cost of alterations
and the cost of storing any of Tenant's property left on the Premises at the
time of reletting, and (iii) to the payment of basic rent or direct expenses
due and unpaid hereunder. The residue, if any, shall be held by Landlord and
applied in payment of future rent or

<PAGE>

damages in the event of termination as the same may become due and payable
hereunder and the balance, if any at the end of the term of this lease, shall
be paid to Tenant. Should the basic rent and direct expenses received from
time to time from such reletting during any month be less than that agreed to
be paid during that month by Tenant hereunder, Tenant shall pay such
deficiency to Landlord. Such deficiency shall be calculated and paid monthly.
No such reletting of the Premises by Landlord shall be construed as election
on its part to terminate this lease unless a written notice of such intention
if given to Tenant or unless the termination hereof is decreed by a court of
competent jurisdiction. Notwithstanding any such reletting without
termination, Landlord may at any time thereafter elect to terminate this
lease for such previous breach, provided it has not been cured.

                  Should Landlord at any time terminate this lease for any
breach, in addition to any other remedy it may have, it shall have the
immediate right of entry and may remove all persons and property from the
Premises and shall have all the rights and remedies of a landlord provided by
California Civil Code Section 1951.2 or any successor code section. Upon such
termination, in addition to all its other rights and remedies, Landlord shall
be entitled to recover from Tenant all damages it may incur by reason of such
breach, including the cost of recovering the Premises and including (i) the
worth at the time of award of the unpaid rent which had been earned at the
time of termination, (ii) the worth at the time of award of the amount by
which the unpaid rent which would have been earned after termination until
the time of award exceeds the amount of such rental loss that Tenant proves
could have been reasonably avoided, (iii) the worth at the time of the award
of the amount by which the unpaid rent for the balance of the term after the
time of award exceeds the amount of such rental loss that Tenant proves could
be reasonably avoided, (iv) any other amount necessary to compensate Landlord
for all the detriment proximately caused by Tenant's failure to perform its
obligations under this lease or which in the ordinary course of events would
be likely to result therefrom. The "worth at the time of award" of the
amounts referred to in (i) and (ii) above is computed by allowing interest at
the rate of twelve percent (12%) per annum. The "worth at the time of award"
of the amount referred to in (iii) above shall be computed by discounting
such amount at the discount rate of the federal reserve bank of San Francisco
at the time of award plus one percent (1%). Tenant waives the provisions of
Section 1179 of the California Code of Civil Procedure (which Section allows
Tenant to petition a court of competent jurisdiction for relief against
forfeiture of this lease). Property removed from the Premises may be stored
in a public or private warehouse or elsewhere at the sole cost and expense of
Tenant. In the event that Tenant shall not immediately pay the cost of
storage of such property after the same has been stored for a period of
thirty (30) days or more, Landlord may sell any or all thereof at a public or
private sale in such manner and at such times and places that Landlord, in
its sole discretion, may deem proper, without notice to or demand upon Tenant.

         20.      LANDLORD'S RIGHT TO CURE TENANT'S DEFAULT

<PAGE>

                  Landlord, at any time after Tenant commits a default, may,
but shall not be obligated to, cure the default at Tenant's cost. If Landlord
at any time, by reason of Tenant's default, pays any sum or does any act that
requires the payment of any sum, the sum paid by Landlord shall be due
immediately from Tenant to Landlord and shall bear interest at the rate of
twelve percent (12%) per annum or the maximum rate permitted by law,
whichever is less, from the date the sum is paid by Landlord until Landlord
is reimbursed by Tenant. Amounts due Landlord hereunder shall be additional
rent.

         21.      EMINENT DOMAIN

                  If all or any part of the Premises shall be taken by any
public or quasi-public authority under the power of eminent domain or
conveyance in lieu thereof, this lease shall terminate as to any portion of
the Premises so taken or conveyed on the date when title vests in the
condemnor, and Landlord shall be entitled to any and all payments, income,
rent, award or any interest therein whatsoever which may be paid or made in
connection with such taking or conveyance. Tenant shall have no claim against
Landlord or otherwise for the value of any unexpired term of this lease.
Notwithstanding the foregoing, Tenant shall be entitled to any compensation
for depreciation to and cost of removal of Tenant's equipment and fixtures
and any compensation for its relocation expenses necessitated by such taking,
but in each case only to the extent the condemning authority makes a separate
award therefor or specifically identifies a portion of the award as being
therefor. Each party waives the provisions of Section 1265.130 of the
California Code of Civil Procedure (which section allows either party to
petition the Superior Court to terminate this lease in the event of a partial
taking of the Premises).

                  If any action or proceeding is commenced for such taking of
the Premises or any portion thereof or of any other space in the Project, or
if Landlord is advised in writing by any entity or body having the right or
power of condemnation of its intention to condemn the premises or any portion
thereof or of any other space in the Project, and Landlord shall decide to
discontinue the use and operation of the Project or decide to demolish, alter
or rebuild the Project, then Landlord shall have the right to terminate this
lease by giving Tenant written notice thereof within sixty (60) days of the
earlier of the date of Landlord's receipt of such notice of intention to
condemn or the commencement of said action or proceeding. Such termination
shall be effective as of the last day of the calendar month next following
the month in which such notice is given or the date on which title shall vest
in the condemnor, whichever occurs first.

                  In the event of a partial taking, or conveyance in lieu
thereof, of the Premises and fifty percent (50%) or more of the number of
square feet in the Premises are taken then Tenant may terminate this lease.
Any election by Tenant to so terminate shall be by written notice given to
Landlord within sixty (60) days from the date of such taking or conveyance
and shall be effective on the last day of the calendar month next following
the month in which such notice is given or the date on which title shall vest
in the condemnor, whichever occurs first.

<PAGE>

                  If a portion of the Premises is taken by power of eminent
domain or conveyance in lieu thereof and neither Landlord nor Tenant
terminates this lease as provided above, then this lease shall continue in
full force and effect as to the part of the Premises not so taken or conveyed
and all payments of rent shall be apportioned as of the date of such taking
or conveyance so that thereafter the amounts to be paid by Tenant shall be in
the ratio that the area of the portion of the Premises not so taken bears to
the total area of the Premises prior to such taking.

         22.      NOTICE AND COVENANT TO SURRENDER

                  On the last day of the term or on the effective date of any
earlier termination, Tenant shall surrender to Landlord the Premises in its
condition existing as of the commencement of the term and, except as
otherwise provided by Landlord pursuant to the terms of paragraph 8 of this
lease, all of the improvements and alterations made to the Premises in their
condition existing as of the date of completion of construction and/or
installation (normal wear and tear excepted), with all originally painted
interior walls washed or repainted if marked or damaged, interior vinyl
covered walls cleaned and repaired or replaced if marked or damaged, all
carpets shampooed and cleaned, and all floors cleaned and waxed; all to the
reasonable satisfaction of Landlord. On or prior to the last day of the term
or the effective date of any earlier termination, Tenant shall remove all of
Tenant's personal property and trade fixtures, together with improvements or
alterations that Tenant is obligated to remove pursuant to the provisions of
paragraph 8 of this lease, from the Premises, and all such property not
removed shall be deemed abandoned. In addition, on or prior to the expiration
or earlier termination of this lease, Tenant shall remove, at Tenant's sole
cost and expense, all telephone, other communication, computer and any other
cabling and wiring or any sort installed in the space above the suspended
ceiling of the Premises or anywhere else in the Premises and shall promptly
repair any damage to the suspended ceiling, lights, light fixtures, walls and
any other part of the Premises resulting from such removal.

                  If the Premises are not surrendered as required in this
paragraph 22, Tenant shall indemnify Landlord against all loss, liability and
expense (including, but not limited to, attorney fees) resulting from the
failure by Tenant in so surrendering the Premises, including, without
limitation, any claims made by any succeeding tenants. It is agreed between
Landlord and Tenant that the provisions of this paragraph 22 shall survive
termination of this lease.

         23.      TENANT'S QUITCLAIM

                  At the expiration or earlier termination of this lease,
Tenant shall execute, acknowledge and deliver to Landlord, within ten (10)
days after written demand from Landlord to Tenant, any quitclaim deed or
other document required to remove the cloud or encumbrance created by this
lease from the real property of which the Premises are a part. This
obligation shall survive said expiration or termination.

<PAGE>

         24.      HOLDING OVER

                  Any holding over after the expiration or termination of
this lease with the written consent of Landlord shall be construed to be a
tenancy from month-to-month at the monthly rent agreed upon by Landlord and
Tenant, but in no event less than the monthly rent payable under this lease
for the last lease month before the date of such expiration or termination.
All provisions of this lease, except (i) as modified by the preceding
sentence and (ii) those provisions pertaining to the term, expansion rights
and any option to extend, shall apply to the month-to-month tenancy.

                  If Tenant shall retain possession of the Premises or any
part thereof without Landlord's written consent following the expiration or
sooner termination of this lease for any reason, then Tenant shall pay to
Landlord as rent during the holdover period an amount equal to the greater of
(i) one hundred fifty percent (150%) of the amount of the monthly rent in
effect during the last full lease month prior to the date of such expiration
or termination or (ii) one hundred twenty-five percent (125%) of the fair
market rental (as reasonably determined by Landlord) for the Premises. Tenant
shall also indemnify and hold Landlord harmless from any loss, liability and
expense (including, but not limited to, attorneys fees) resulting from delay
by Tenant in surrendering the Premises, including without limitation any
claims made by any succeeding tenant founded on such delay. Acceptance of
rent by Landlord following expiration or termination shall not constitute a
renewal of this lease, and nothing contained in this paragraph shall waive
Landlord's right of re-entry or any other right. Tenant shall be only a
tenant at sufferance, whether or not Landlord accepts any rent from Tenant,
while Tenant is holding over without Landlord's written consent.

                  The provisions of this paragraph 24 are in addition to, and
do not affect, Landlord's right of re-entry or other rights hereunder or
provided by law. Nothing in this paragraph 24 shall be construed as implied
consent by Landlord to any holding over by Tenant. Landlord expressly
reserves the right to require Tenant to surrender possession of the Premises
to Landlord as provided in this Lease on expiration or other termination of
this Lease. The provisions of this paragraph 24 shall not be considered to
limit or constitute a waiver of any other rights or remedies of Landlord
provided in this Lease or at law. The provisions of this paragraph 24 shall
survive the expiration or early termination of this lease.

         25.      SUBORDINATION

                  In the event Landlord's title or leasehold interest is now
or hereafter encumbered in order to secure a loan to Landlord, Tenant shall,
at the request of Landlord or the lender, execute in writing an agreement
subordinating its rights under this lease to the lien of such encumbrance,
or, if so requested, agreeing that the lien of lender's encumbrance shall be
or remain subject and subordinate to the rights of Tenant under this lease.
Tenant hereby irrevocably appoints Landlord the attorney in fact of Tenant to
execute, deliver and record any such instrument or instruments for and

<PAGE>

in the name and on behalf of Tenant. Notwithstanding any such subordination,
Tenant's possession under this lease shall not be disturbed if Tenant is not
in default and so long as Tenant shall pay all amounts due hereunder and
otherwise observe and perform all provisions of this lease. In addition, if
in connection with any such loan the lender shall request reasonable
modifications in this lease as a condition to such financing, Tenant will not
unreasonably withhold, delay or defer its consent thereof, provided that such
modifications do not increase the obligations of Tenant hereunder or
materially adversely affect the leasehold interest hereby created or Tenant's
rights hereunder.

         26.      CERTIFICATE OF ESTOPPEL

                  Each party shall, within five (5) calendar days after request
therefor, execute and deliver to the other party, in recordable form, a
certificate stating that the lease is unmodified and in full force and effect,
or in full force and effect as modified and stating the modifications. The
certificate shall also state the amount of the monthly rent, the date to which
monthly rent has been paid in advance, the amount of the security deposit and/or
prepaid monthly rent, and, if the request is made by Landlord, shall include
such other items as Landlord or Landlord's lender may reasonably request.
Failure to deliver such certificate within such time shall constitute a
conclusive acknowledgment by the party failing to deliver the certificate that
the lease is in full force and effect and has not been modified except as may be
represented by the party requesting the certificate. Any such certificate
requested by Landlord may be conclusively relied upon by any prospective
purchaser or encumbrancer of the Premises or Project. Further, within five (5)
calendar days following written request made from time to time by Landlord,
Tenant shall furnish to Landlord current financial statements of Tenant.

         27.      SALE BY LANDLORD

                  In the event the original Landlord hereunder, or any successor
owner of the Project or Premises, shall sell or convey the Project or Premises,
all liabilities and obligations on the part of the original Landlord, or such
successor owner, under this lease accruing thereafter shall terminate, and
thereupon all such liabilities and obligations shall be binding upon the new
owner. Tenant agrees to attorn to such new owner and to look solely to such new
owner for performance of any and all such liabilities and obligations.

         28.      ATTORNMENT TO LENDER OR THIRD PARTY

                  In the event the interest of Landlord in the land and
buildings in which the Premises are located (whether such interest of Landlord
is a fee title interest or a leasehold interest) is encumbered by deed of trust,
and such interest is acquired by a lender or any other third party through
judicial foreclosure or by exercise of a power of sale at private trustee's
foreclosure sale, Tenant hereby agrees to release Landlord of any obligation
arising on or after any such foreclosure sale and to attorn to the

<PAGE>

purchaser at any such foreclosure sale and to recognize such purchaser as the
Landlord under this lease.

         29.      DEFAULT BY LANDLORD

                  Landlord shall not be in default unless Landlord fails to
perform obligations required of Landlord within a reasonable time, but in no
event earlier than thirty (30) days after written notice by Tenant to Landlord
and to the holder of any first mortgage or deed of trust covering the Premises
specifying wherein Landlord has failed to perform such obligations; provided,
however, that if the nature of Landlord's obligations is such that more than
thirty (30) days are required for performance, then Landlord shall not be in
default if Landlord commences performance within such thirty (30) day period and
thereafter diligently prosecutes the same to completion.

                  If Landlord is in default of this lease, Tenant's sole remedy
shall be to institute suit against Landlord in a court of competent
jurisdiction, and Tenant shall have no right to offset any sums expended by
Tenant as a result of Landlord's default against future rent and other sums due
and payable pursuant to this lease. If Landlord is in default of this lease, and
as a consequence Tenant recovers a money judgment against Landlord, the judgment
shall be satisfied only out of the proceeds of sale received on execution of the
judgment and levy against the right, title and interest of Landlord in the
Project of which the Premises are a part, and out of rent or other income from
such real property receivable by Landlord or out of the consideration received
by Landlord from the sale or other disposition of all or any part of Landlord's
right, title and interest in the Project of which the Premises are a part.
Neither Landlord nor any of the partners comprising the partnership designated
as Landlord shall be personally liable for any deficiency.

         30.      CONSTRUCTION CHANGES

                  It is understood that the description of the Premises and the
location of ductwork, plumbing and other facilities therein are subject to such
changes as Landlord or Landlord's architect determines to be desirable in the
course of construction of the Premises and/or the improvements constructed or
being constructed therein, and no such changes or any changes in plans for any
other portions of the Project, shall affect this lease or entitle Tenant to any
reduction of rent hereunder or result in any liability of Landlord to Tenant.

         31.      MEASUREMENT OF PREMISES

                  Tenant understands and agrees that any reference to square
footage of the Premises is approximate only and includes all interior partitions
and columns, one-half of exterior walls, and one-half of the partitions
separating the Premises from the rest of the Project. Tenant waives any claim
against Landlord regarding the accuracy of any such measurement and agrees that
there shall not be any adjustment

<PAGE>

in basic rent or direct expenses or other amounts payable hereunder by reason
of inaccuracies in such measurement.

         32.      ATTORNEY FEES

                  If either party commences an action against the other party
arising out of or in connection with this lease, the prevailing party shall be
entitled to have and recover from the losing party all expenses of litigation,
including, without limitation, travel expenses, attorney fees, expert witness
fees, trial and appellate court costs, and deposition and transcript expenses.
If either party becomes a party to any litigation concerning this lease or
concerning the Premises or the Project by reason of any act or omission of the
other party or its authorized representatives, the party that causes the other
party to become involved in the litigation shall be liable to the other party
for all expenses of litigation, including, without limitation, travel expenses,
attorney fees, expert witness fees, trial and appellate court costs, and
deposition and transcript expenses.

         33.      SURRENDER

                  The voluntary or other surrender of this lease or the Premises
by Tenant, or a mutual cancellation of this lease, shall not work a merger, and
at the option of Landlord shall either terminate all or any existing subleases
or subtenancies or operate as an assignment to Landlord of all or any such
subleases or subtenancies.

         34.      WAIVER

                  No delay or omission in the exercise of any right or remedy of
Landlord on any default by Tenant shall impair such right or remedy or be
construed as a waiver. The receipt and acceptance by Landlord of delinquent rent
or other payments shall not constitute a waiver of any other default and
acceptance of partial payments shall not be construed as a waiver of the balance
of such payment due. No act or conduct of Landlord, including, without
limitation, the acceptance of keys to the Premises, shall constitute an
acceptance of the surrender of the Premises by Tenant before the expiration of
the term. Only a written notice from Landlord to Tenant shall constitute
acceptance of the surrender of the Premises and accomplish a termination of this
lease. Landlord's consent to or approval of any act by Tenant requiring
Landlord's consent or approval shall not be deemed to waive or render
unnecessary Landlord's consent to or approval of any subsequent act by Tenant.
Any waiver by Landlord of any default must be in writing and shall not be a
waiver of any other default concerning the same or any other provision of this
lease.

         35.      EASEMENTS; AIRSPACE RIGHTS

                  Landlord reserves the right to alter the boundaries of the
Project and grant easements and dedicate for public use portions of the Project
without Tenant's consent, provided that no such grant or dedication shall
interfere with Tenant's use of the

<PAGE>

Premises or otherwise cause Tenant to incur cost or expense. From time to
time, and upon Landlord's demand, Tenant shall execute, acknowledge and
deliver to Landlord, in accordance with Landlord's instructions, any and all
documents, instruments, maps or plats necessary to effectuate Tenant's
covenants hereunder.

                  This lease confers no rights either with regard to the
subsurface of or airspace above the land on which the Project is located or with
regard to airspace above the building of which the Premises are a part. Tenant
agrees that no diminution or shutting off of light or view by a structure which
is or may be erected (whether or not by Landlord) on property adjacent to the
building of which the Premises are a part or to property adjacent thereto, shall
in any way affect this lease, or entitle Tenant to any reduction of rent, or
result in any liability of Landlord to Tenant.

         36.      RULES AND REGULATIONS

                  Landlord shall have the right from time to time to promulgate
rules and regulations for the safety, care and cleanliness of the Premises, the
Project and the Common Area, or for the preservation of good order. On delivery
of a copy of such rules and regulations to Tenant, Tenant shall comply with the
rules and regulations, and a violation of any of them shall constitute a default
by Tenant under this lease. If there is a conflict between the rules and
regulations and any of the provisions of this lease, the provisions of this
lease shall prevail. Such rules and regulations may be amended by Landlord from
time to time with or without advance notice.

         37.      NOTICES

                  Except for legal process and Notice of Belief of Abandonment
which may be served either as provided by law or as provided herein, all
notices, demands, requests, consents, approvals and other communications
("Notices") which may be given or are required to be given by either party to
the other shall be in writing and shall be deemed given to and received by the
party intended to receive such Notice and deemed sufficiently given for all
purposes as follows:

                  (a)      when personally delivered to the recipient, notice
is effective on delivery;

                  (b) when mailed first class to the last address of the
recipient known to the party giving notice, notice is effective on delivery;

                  (c) when mailed by certified mail with return receipt
requested, notice is effective on receipt if delivery is confirmed by a return
receipt; or

                  (d) when delivered by reputable overnight courier (e.g.
Federal Express, Airborne) or other comparable service with charges prepaid or
charged to the sender's account, notice is effective on delivery if delivery is
confirmed by the courier service.

<PAGE>

                  Any correctly addressed Notice that is refused, unclaimed, or
undeliverable because of an act or omission of the party to be notified shall be
deemed effective as of the first date that the Notice was refused, unclaimed, or
considered undeliverable by the postal authorities, messenger, or overnight
delivery service.

                  Prior to the commencement date, all such Notices from Landlord
to Tenant shall be served or addressed to Tenant at 20600 Mariani Avenue,
Cupertino, California 95014. On or after the commencement date all such Notices
from Landlord to Tenant shall be addressed to Tenant at the Premises.

                  All such Notices by Tenant to Landlord shall be sent to
Landlord at _______________________________________, with a copy to McCandless
Management Corporation at 3945 Freedom Circle, Suite 640, Santa Clara,
California 95054.

                  Either party may change its address by giving the other party
notice of such change in any manner permitted by this paragraph 37.

         38.      NAME

                  Tenant shall not use the name of the Project for any purpose
other than as the address of the business conducted by Tenant in the Premises
without the prior written consent of Landlord.

         39.      GOVERNING LAW; SEVERABILITY

                  This lease shall in all respects be governed by and construed
in accordance with the laws of the State of California. If any provision of this
lease shall be held or rendered invalid, unenforceable or ineffective for any
reason whatsoever, all other provisions hereof shall be and remain in full force
and effect.

         40.      DEFINITIONS

                  As used in this lease, the following words and phrases shall
have the following meanings:

                  AUTHORIZED REPRESENTATIVE: any officer, agent, employee or
independent contractor retained or employed by either party, acting within
authority given him by that party.

                  ENCUMBRANCE: any deed of trust, mortgage or other written
security device or agreement affecting the Premises or the Project that
constitutes security for the payment of a debt or performance of an obligation,
and the note or obligation secured by such deed of trust, mortgage or other
written security device or agreement.

<PAGE>

                  LEASE MONTH: the period of time determined by reference to the
day of the month in which the term commences and continuing to one day short of
the same numbered day in the next succeeding month; e.g., the tenth day of one
month to and including the ninth day in the next succeeding month.

                  LEASE YEAR: the period of time determined by reference to the
day of the year in which the term commences and continuing to one day short of
the same day in the next succeeding year; e.g., the tenth day of July of one
year to the ninth day of July of the next succeeding year.

                  LENDER:  the beneficiary, mortgagee or other holder of an
encumbrance, as defined above.

                  LIEN: a charge  imposed on the Premises by someone other
than  Landlord,  by which the Premises are made security for the performance
of an act.  Most of the liens referred to in this lease are mechanic's liens.

                  MAINTENANCE:  repairs, replacement, repainting and cleaning.

                  MONTHLY RENT:  the sum of the monthly payments of basic
rent and direct expenses.

                  PERSON:  one or more human beings,  or legal entities or
other artificial  persons,  including,  without  limitation, partnerships,
corporations, trusts, estates, associations and any combination of human
being and legal entities.

                  PROVISION:  any term,  agreement,  covenant,  condition,
clause,  qualification,  restriction,  reservation or other stipulation  in
the lease that defines or otherwise  controls,  establishes or limits the
performance  required or permitted by either party.

                  RENT: basic rent,  direct expenses,  additional rent and
all other amounts payable by Tenant to Landlord  required by this lease or
arising by subsequent actions of the parties made pursuant to this lease.

                  Words used in any gender include other genders. If more
than one individual or entity comprises Tenant, the obligations imposed on
each individual or entity that comprises Tenant under this Lease are and
shall be joint and several. All provisions whether covenants or conditions,
on the part of Tenant shall be deemed to be both covenants and conditions.
The paragraph headings are for convenience of reference only and shall have
no effect upon the construction or interpretation of any provision hereof.

         41.      TIME

                  Time is of the essence of this lease and of each and all of
its provisions.

<PAGE>

         42.      INTEREST ON PAST DUE OBLIGATIONS; LATE CHARGE

                  Any amount due from Tenant to Landlord hereunder which is not
paid when due shall bear interest at the rate of ten percent (10%) per annum
from when due until paid, unless otherwise specifically provided herein, but the
payment of such interest shall not excuse or cure any default by Tenant under
this lease. In addition, Tenant acknowledges that late payment by Tenant to
Landlord of basic rent or direct expenses or of any other amount due Landlord
from Tenant, will cause Landlord to incur costs not contemplated by this lease,
the exact amount of such costs being extremely difficult and impractical to fix.
Such costs include, without limitation, processing and accounting charges, and
late charges that may be imposed on Landlord, e.g., by the terms of any
encumbrance and note secured by any encumbrance covering the Premises.
Therefore, if any such payment due from Tenant is not received in full by
Landlord when due, which payments are subject to application by Landlord as
provided in paragraph 4 of this lease, Tenant shall pay to Landlord an
additional sum of five percent (5%) of the entire payment as a late charge. The
parties agree that this late charge represents a fair and reasonably estimate of
the costs that Landlord will incur by reason of late payment by Tenant.
Acceptance of any late charge shall not constitute a waiver of Tenant's default
with respect to the overdue amount, nor prevent Landlord from exercising any of
the other rights and remedies available to Landlord. No notice to Tenant of
failure to pay shall be required prior to the imposition of such interest and/or
late charge, and any notice period provided for in paragraph 19 shall not affect
the imposition of such interest and/or late charge. Any interest and late charge
imposed pursuant to this paragraph shall be and constitute additional rent
payable by Tenant to Landlord.

         43.      ENTIRE AGREEMENT

                  This lease, including any exhibits and attachments,
constitutes the entire agreement between Landlord and Tenant relative to the
Premises and this lease and the exhibits and attachments may be altered, amended
or revoked only by an instrument in writing signed by both Landlord and Tenant.
Landlord and Tenant agree hereby that all prior or contemporaneous oral
agreements between and among themselves or their agents or representatives
relative to the leasing of the Premises are merged in or revoked by this lease.

         44.      AUTHORITY

                  Each individual executing this lease on behalf of Tenant
represents and warrants that (i) he/she is duly authorized to execute and
deliver this lease on behalf of Tenant and: (a) if Tenant is a corporation, such
authorization is in accordance with a duly adopted resolution of the Board of
Directors of said corporation, (b) if Tenant is a

<PAGE>

partnership, such authorization is in accordance with the partnership
agreement now in effect, and (c) if Tenant is a limited liability company,
such authorization is in accordance with the company's governing documents;
and (ii) this lease is binding upon Tenant in accordance with its terms. Upon
Landlord's request, Tenant shall deliver to Landlord within ten (10) days
after such request evidence of the authorization specified above as Landlord
may reasonably request, including, without limitation, in the case where
Tenant is a corporation, a copy of the resolution of the Board of Directors
of Tenant authorizing the execution of this lease and naming the officers
that are authorized to execute this lease on behalf of Tenant, which copy
shall be certified by Tenant's secretary as correct and in full force and
effect.

         45.      RECORDING

                  Neither  Landlord  nor Tenant shall record this lease or a
short form  memorandum  hereof  without the consent of the other.

         46.      EXHIBITS AND ATTACHMENTS

                  All exhibits and attachments to this lease are a part hereof
and the terms and provisions thereof are incorporated into this lease by this
reference as though set forth herein in full.

         47.      REAL ESTATE BROKERS

                  Each party represents and warrants to the other party that it
has not had dealings in any manner with any real estate broker, finder or other
person with respect to the Premises and the negotiation and execution of this
lease except CRESA Partners ("CRESA", representing Landlord) and MacMillan,
Moore & Buchanan, Inc. ("MMBI", representing Tenant). Except for the commissions
and fees to be paid to CRESA and MMBI as provided in this paragraph, each party
shall indemnify and hold harmless the other party from all damage, loss,
liability and expense (including attorneys' fees and related costs) arising out
of or resulting from any claims for commissions or fees that have been or may be
asserted against the other party by any broker, finder or other person with whom
Tenant or Landlord, respectively, has dealt, or purportedly has dealt, in
connection with the Premises and the negotiation and execution of this lease.
Landlord shall pay broker leasing commissions to CRESA and MMBI in connection
with the Premises and the negotiation and execution of this lease, to the extent
agreed to between Landlord and CRESA. Landlord and Tenant agree that Landlord
shall not be obligated to pay any broker leasing commissions, consulting fees,
finder fees or any other fees or commissions arising out of or relating to any
extended term of this lease or to any expansion or relocation of the Premises at
any time.

         48.      ENVIRONMENTAL MATTERS

                  A.       TENANT'S COVENANTS REGARDING HAZARDOUS MATERIALS.

<PAGE>

                     (1)  HAZARDOUS MATERIALS HANDLING.  Tenant, its
agents, invitees, employees, contractors, sublessees, assigns and/or
successors shall not use, store, dispose, release or otherwise cause to be
present or permit the use, storage, disposal, release or presence of
Hazardous Materials (as defined below) on or about the Premises or Project.
As used herein "Hazardous Materials" shall mean any petroleum or petroleum
by-products, flammable explosives, asbestos, urea formaldehyde, radioactive
materials or waste and any "hazardous substance", "hazardous waste",
"hazardous materials", "toxic substance" or "toxic waste" as those terms are
defined under the provisions of the California Health and Safety Code and/or
the provisions of the Comprehensive Environmental Response, Compensation and
Liability Act (42 U.S.C. Section 9601 et seq.), as amended by the Superfund
Amendments and Reauthorization Act of 1986 (42 U.S.C. Section 9601 et seq.),
or any other hazardous or toxic substance, material or waste which is or
becomes regulated by any local governmental authority, the State of
California or any agency thereof, or the United States Government or any
agency thereof.

                           (2) NOTICES. Tenant shall immediately notify
Landlord in writing of: (i) any enforcement, cleanup, removal or other
governmental or regulatory action instituted, completed or threatened
pursuant to any law, regulation or ordinance relating to the industrial
hygiene, environmental protection or the use, analysis, generation,
manufacture, storage, presence, disposal or transportation of any Hazardous
Materials (collectively "Hazardous Materials Laws"); (ii) any claim made or
threatened by any person against Tenant, the Premises, Project or buildings
within the Project relating to damage, contribution, cost recovery,
compensation, loss or injury resulting from or claimed to result from any
Hazardous Materials; and (iii) any reports made to any environmental agency
arising out of or in connection with any Hazardous Materials in, on or
removed from the Premises, Project or buildings within the Project, including
any complaints, notices, warnings, reports or asserted violations in
connection therewith. Tenant shall also supply to Landlord as promptly as
possible, and in any event within five (5) business days after Tenant first
receives or sends the same, with copies of all claims, reports, complaints,
notices, warnings or asserted violations relating in any way to the Premises,
Project or buildings within the Project or Tenant's use thereof. Tenant shall
promptly deliver to Landlord copies of hazardous waste manifests reflecting
the legal and proper disposal of all Hazardous Materials removed from the
Premises.

                  B. INDEMNIFICATION OF LANDLORD. Tenant shall indemnify, defend
(by counsel reasonably acceptable to Landlord), protect, and hold Landlord, and
each of Landlord's partners, employees, agents, attorneys, successors and
assigns, free and harmless from and against any and all claims, liabilities,
penalties, forfeitures, losses or expenses (including attorneys' fees) for death
of or injury to any person or damage to any property whatsoever (including water
tables and atmosphere), arising from or caused in whole or in part, directly or
indirectly, by (i) the presence in, on, under or about the Premises, Project or
buildings within the Project where such presence or discharge was caused by
Tenant, (ii) Tenant's use, analysis, storage, transportation, disposal, release,
threatened release, discharge or generation of Hazardous Materials to, in, on,
under, about or from the Premises, Project or buildings within the Project, or

<PAGE>

(iii) Tenant's failure to comply with any Hazardous Materials Laws whether
knowingly, unknowingly, intentionally or unintentionally. Tenant's obligations
hereunder shall include, without limitation, and whether foreseeable or
unforeseeable, all costs of any required or necessary repair, cleanup or
detoxification or decontamination of the Premises, Project or buildings within
the Project, and the preparation and implementation of any closure, remedial
action or other required plans in connection therewith. In addition, Tenant
shall reimburse Landlord for (i) losses in or reductions to rental income
resulting from Tenant's use, storage or disposal of Hazardous Materials, (ii)
all costs of refitting or other alterations to the Premises, Project or
buildings within the Project required as a result of Tenant's use, storage, or
disposal of Hazardous Materials including, without limitation, alterations
required to accommodate an alternate use of the Premises, Project or buildings
within the Project, and (iii) any diminution in the fair market value of the
Premises, Project or buildings within the Project caused by Tenant's use,
storage, or disposal of Hazardous Materials. For purposes of this paragraph 48,
any acts or omissions of Tenant, or by employees, agents, assignees, contractors
or subcontractors of Tenant or others acting for or on behalf of Tenant (whether
or not they are negligent, intentional, willful or unlawful) shall be strictly
attributable to Tenant.

                  C.       SURVIVAL.  The provisions of this paragraph 48
shall survive the expiration or earlier termination of the term of this lease.

     49.   SIGNAGE

           Tenant shall not, without obtaining the prior written consent of
Landlord, install or attach any sign or advertising material on any part of
the outside of the Premises, or on any part of the inside of the Premises
which is visible from the outside of the Premises, or in the halls, lobbies,
windows or elevators of the building in which the Premises are located or on
or about any other portion of the Common Area or Project. Subject to the
terms of this paragraph 49, Tenant shall have the right to use approximately
the lower one-half of the existing monument sign for the building. If
Landlord consents to the installation of any sign or other advertising
material, the location, size, design, color and other physical aspects
thereof shall be subject to Landlord's prior written approval and shall be in
accordance with any sign program applicable to the Project. In addition to
any other requirements of this paragraph 49, the installation of any sign or
other advertising material by or for Tenant must comply with all applicable
laws, statutes, requirements, rules, ordinances and any C.C. & R.'s or other
similar requirements. With respect to any permitted sign installed by or for
Tenant, Tenant shall maintain such sign or other advertising material in good
condition and repair and shall remove such sign or other advertising material
on the expiration or earlier termination of the term of this lease. The cost
of any permitted sign or advertising material and all costs associated with
the installation, maintenance and removal thereof shall be paid for solely by
Tenant. If Tenant fails to properly maintain or remove any permitted sign or
other advertising material, Landlord may do so at Tenant's expense. Any cost
incurred by Landlord in connection with such maintenance or removal shall be
deemed additional rent and shall be paid by Tenant to Landlord

<PAGE>

within ten (10) days following notice from Landlord. Landlord may remove any
unpermitted sign or advertising material without notice to Tenant and the
cost of such removal shall be additional rent and shall be paid by Tenant
within ten (10) days following notice from Landlord. Landlord shall not be
liable to Tenant for any damage, loss or expense resulting from Landlord's
removal of any sign or advertising material in accordance with this paragraph
49. The provisions of this paragraph 49 shall survive the expiration or
earlier termination of this lease.

     50.   SUBMISSION OF LEASE

         The submission of this lease to Tenant for examination or
signature by Tenant is not an offer to lease the Premises to Tenant nor an
agreement by Landlord to reserve the Premises for Tenant. Landlord will not be
bound to Tenant until this lease has been duly executed and delivered by both
Landlord and Tenant.

     51.   TENANT IMPROVEMENTS

         Improvements to the Premises shall be constructed and
installed in accordance with the plans and specifications, and other terms and
conditions set forth in Exhibit C to this lease, the contents of which are
incorporated herein and made a part hereof by this reference. The improvements
shall be constructed and installed at the expense of Landlord and/or Tenant as
set forth in Exhibit C to this lease and in each case shall be performed in a
diligent and workmanlike manner.

     52.   ADDITIONAL RENT

         All costs, charges, fees, penalties, interest and any other
payments (including Tenant's reimbursement to Landlord of costs incurred by
Landlord) which Tenant is required to make to Landlord pursuant to the terms and
conditions of this lease and any amendments to this lease shall be and
constitute additional rent payable by Tenant to Landlord when due as specified
in this lease and any amendments to this lease.

     53.   [INTENTIONALLY OMITTED]

     IN WITNESS WHEREOF, Landlord and Tenant have executed and delivered
this lease on the date first above written.

<PAGE>

LANDLORD:                               TENANT:

SYMANTEC CORPORATION,                   AUDIOHIGHWAY.COM,
a Delaware corporation                  a California corporation

By:___________________________          By:___________________________

Name:_________________________          Name:_________________________

Title:________________________          Title:   PRESIDENT

Date:_________________________          Date:_________________________

                                        By:___________________________

                                        Name:_________________________

                                        Title:   SECRETARY

                                        Date:_________________________

<PAGE>

                        WORK LETTER AGREEMENT
                      EXISTING SPACE - ALLOWANCE

CONSTRUCTION                      EXHIBIT C

     THIS WORK LETTER AGREEMENT (hereinafter "Exhibit C") is attached to and
forms a part of that certain lease ("Lease") by and between SYMANTEC
CORPORATION, a Delaware corporation ("Landlord"), and AUDIOHIGHWAY.COM, a
California corporation ("Tenant"), pursuant to which Landlord leases to Tenant
those certain premises located at 20300 Steven Creek Boulevard, Suite 100,
Cupertino, California and consisting of approximately twenty-six thousand nine
hundred sixty-seven (26,967) square feet ("Premises"). All capitalized terms
used herein shall have the meaning ascribed to them in the Lease unless
otherwise defined herein. The Premises shall be improved in accordance with the
following:

     1.    EXISTING IMPROVEMENTS:

           Tenant accepts the Premises in their existing condition and
the improvements constructed therein (the "Existing Improvements"), and Tenant
hereby approves the same as installed, subject only to construction of the
Tenant Improvements specified herein and such changes as may subsequently be
agreed upon by Landlord and Tenant.

     2.    TENANT IMPROVEMENTS:

           As used herein, "Tenant Improvements" shall include those
items and specifications shown on the Final Construction Documents prepared in
accordance with paragraph 3 below, including those specifications (as
appropriate) set forth and described in Exhibit C-1, attached hereto, exclusive
of Existing Improvements. Landlord shall construct Tenant Improvements in
accordance with the Final Construction Documents and the provisions of this
Exhibit C. Unless otherwise specifically agreed to by Landlord in writing, the
installation, wiring, maintenance and removal of furniture partition systems,
telephone and other communication systems, data cabling, alarm and/or security
systems and any other systems not specifically set forth in the Final
Construction Documents and all cost and expense associated therewith, shall be
the sole responsibility of Tenant. In connection with the construction and
installation of the Tenant Improvements, Landlord and Landlord's general

<PAGE>

contractor shall have no obligation to move any of Tenant's property located in
or about the Premises including, but not limited to, furniture, inventory and
trade fixtures, at the time of such construction and installation. If at the
time of construction and installation of the Tenant Improvements Tenant has
property located in or about the Premises that inhibits or prevents in any way
the construction and installation of the Tenant Improvements, Tenant shall
immediately, upon receipt of notification thereof from Landlord or Landlord's
general contractor, at Tenant's sole cost and expense, move such property to
another location within the Premises or, upon receipt of Landlord's prior
approval, to another location within the Project designated by Landlord in
Landlord's sole discretion; Tenant's failure to immediately move such property
upon receipt of notification thereof from Landlord or Landlord's general
contractor shall be deemed a Tenant caused delay subject to the provisions of
paragraph 8 of this Exhibit C. If at the time of construction and installation
of the Tenant Improvements Tenant has property located in or about the Premises,
Landlord and Landlord's general contractor shall incur no liability to Tenant or
any other party in the event such property is damaged, destroyed or stolen
during the construction and installation of the Tenant Improvements.

     3.    TENANT IMPROVEMENT DESIGN SCHEDULE:

         The plans and specifications for the Tenant Improvements shall
be completed in accordance with the following:

         (a) Tenant shall approve preliminary floor plan layouts
("Preliminary Floor Plans") prepared by Landlord by __________, 1999. The
Preliminary Floor Plans shall show all walls, doors, and other Tenant
Improvements desired by Tenant in sufficient detail for Landlord's architect
to prepare architectural construction drawings and related documents
("Architectural Construction Documents").

         (b) Between ____________, 1999 and ____________, 1999, Landlord's
architect and Tenant's representative shall meet as needed to review and
complete the final details related to the Preliminary Floor Plans, so that on
___________, 1999 the Architectural Construction Documents are subject only
to minor changes.

         (c) No later than _______________, 1999, Tenant shall have made the
decisions required and supplied to Landlord the information necessary for
Landlord's architect to complete the Architectural Construction Documents in
enough detail for Landlord's general contractor to bid the work, select
subcontractors and to proceed toward the design of electrical, mechanical and
any other requirements not included on the Architectural Construction
Documents. Upon Landlord's general contractor's selection of subcontractors,
Landlord's general contractor and subcontractors shall prepare design
specifications outlining in reasonable detail electrical, mechanical and any
other requirements not included on the Architectural Construction Documents
("Electrical and Mechanical Drawings").

<PAGE>

         (d) Upon completion of the Architectural Construction
Documents, Tenant shall approve the same subject to changes, deletions or
additions as provided for in paragraphs 6 and 7 of this Exhibit C.

         (e) Upon completion of the Electrical and Mechanical Drawings,
Landlord or Landlord's general contractor shall submit the Architectural
Construction Documents and Electrical and Mechanical Drawings (collectively the
"City Ready Plans") to the City to obtain a building permit.

         (f) Tenant shall have decided upon carpet selection and all
other color and material specifications by ________________, 1999.

         (g) As used herein, "Final Construction Documents" shall
include the City Ready Plans, as approved by the City, and any subsequent
additions, deletions or changes to the Tenant Improvements permitted or required
pursuant to paragraphs 6 and 7 of this Exhibit C.

     4.    TENANT IMPROVEMENT COST ESTIMATES:

         Within fourteen (14) days of completion of the Electrical and
Mechanical Drawings, Landlord shall prepare and deliver to Tenant an improvement
cost budget ("Improvement Cost Budget") setting forth the Total Cost of Tenant
Improvements (as defined in paragraph 5(b) below). Within three (3) days after
Tenant's receipt of the Improvement Cost Budget, Tenant shall, in writing,
approve or disapprove the Improvement Cost Budget. If Tenant does not deliver to
Landlord its written approval or disapproval within the three (3) day period,
Tenant will be deemed to have approved the Improvement Cost Budget. If Tenant
disapproves the Improvement Cost Budget, Landlord and Tenant shall, within three
(3) days of Tenant's disapproval, attempt to agree on mutually acceptable
modifications to the Improvement Cost Budget. If Tenant disapproves of the
Improvement Cost Budget and Landlord and Tenant are unable, within the three (3)
day period, to agree on mutually acceptable changes to the Improvement Cost
Budget, or if Tenant approves of the Improvement Cost Budget but does not
deliver to Landlord, within three (3) days of its approval, signed copies of the
Improvement Cost Budget and Architectural Construction Documents, then Landlord
may terminate the Lease upon written notice to Tenant. The Improvement Cost
Budget shall be subject to adjustment for increases in costs resulting from
changes to the Tenant Improvements requested or required pursuant to paragraphs
6 and 7 below. Landlord shall not be obligated to commence construction of the
Tenant Improvements until the following has occurred: (i) the Architectural
Construction Documents and the Improvement Cost Budget have been agreed to by
Landlord and Tenant; (ii) Tenant has indicated its approval of the Architectural
Construction Documents and the Improvement Cost Budget by signing copies
thereof; and (iii) Landlord has given written authorization to proceed with
construction to Landlord's general contractor based on the agreed Architectural
Construction Documents and the Improvement Cost Budget.

<PAGE>

     5.    TENANT IMPROVEMENT ALLOWANCE:

           (a) Landlord agrees to grant to Tenant a tenant improvement
allowance of up to $134,835 ("Allowance") to be applied toward the "Total
Cost of Tenant Improvements" (as defined in paragraph 5(b) below) to be
installed in accordance with this Exhibit C.

           (b) As used herein, "Total Cost of Tenant Improvements" shall mean
all costs to construct and install the Tenant Improvements, including,
without limitation, (i) all demolition costs incurred in connection with
preparing the Premises for the installation of the Tenant Improvements and
the actual costs incurred for labor, materials and contractors' fees; (ii)
the cost of overtime or special expenditures required to obtain and install
the Tenant Improvements by the proposed commencement date; (iii) all costs
related to change orders; (iv) all costs related to changes required or
requested by governmental authority; (v) permit fees and other fees not
previously paid by Landlord as part of shell costs; (vi) the cost of
consultants and engineers; (vii) an amount equal to the actual cost of
supervision, administration and on-site facilities and equipment necessary to
perform the work; (viii) an amount equal to ____% of the sum of items (i)
through (vii) above as and for the general contractor's overhead and profit;
and (ix) the cost of architects hired by Landlord.

           (c) In the event that the Improvement Cost Budget exceeds the
Allowance, the amount by which the Improvement Cost Budget exceeds the
Allowance shall be referred to herein as the "Excess Cost". Tenant shall pay
fifty percent (50%) of such Excess Cost to Landlord within five (5) days of
Tenant's approval of the Improvement Cost Budget and the remaining fifty
percent (50%) of the Excess Cost within five (5) days of when Landlord
notifies Tenant that the Tenant Improvements are fifty percent (50%)
completed. Tenant's failure to make any payment of the Excess Cost when due,
or to make any payment with respect to change orders as set forth in
paragraph 6 of this Exhibit C, shall be deemed a default under the Lease and
the amount so delinquent shall be deemed additional rent and Landlord may
exercise all rights and remedies set forth in the Lease; and in addition,
Landlord may delay construction until such payment is made and such delay
shall be deemed a Tenant caused delay subject to the provisions of paragraph
8 of this Exhibit C.

           (d) In the event Tenant causes delays, or requests changes which
cause delays in construction of more than ninety (90) calendar days, then
Landlord shall not be obligated to grant to Tenant the Allowance, or any
balance remaining unused therein. In such case, Landlord shall thereafter
have no obligation to construct any Tenant Improvements for Tenant.
Furthermore, the cessation of Landlord's obligation to construct the Tenant
Improvements as permitted herein shall not affect Tenant's obligation to
commence payments of basic rent and direct expenses or any other payments due
Landlord under the Lease. Tenant shall be entitled to no rent

<PAGE>

reduction or credit at any time in the event that the Allowance or any
portion thereof remains unused for any reason whatsoever.

           (e) Upon completion of the Tenant Improvements, Landlord shall
reconcile the actual Total Cost of the Tenant Improvements to the Improvement
Cost Budget and Landlord shall refund to Tenant any Excess Cost paid by
Tenant to Landlord (as specified in paragraph 5(c) above) that was not
actually incurred.

     6.    CHANGES BY TENANT:

           Tenant may request changes, deletions or additions to the Tenant
Improvements; provided, however, that the effectiveness of any such requested
change, deletion or addition shall be subject to written approval by an
authorized representative of Landlord and to obtaining any required
governmental permits or other approvals. If any such change, deletion or
addition increases the Improvement Cost Budget above the Allowance, Tenant
shall immediately pay to Landlord the full amount of such increase in excess
of the Allowance. In no event shall work on any change, deletion or addition
requested pursuant to this paragraph 6 commence prior to (i) Landlord and
Tenant approving, in writing, such change, deletion or addition, and (ii)
Landlord's receipt from Tenant of payment of the full amount of the increase
in the Improvement Cost Budget in excess of the Allowance.

     7.    CHANGES BY AUTHORITY:

           Tenant agrees that if any change, deletion or addition to any of
the improvements proposed to be constructed or installed is required by any
governmental authority in connection with obtaining any governmental permit
or approval, or otherwise, then such change, deletion or addition shall
promptly be made and the Improvement Cost Budget shall be adjusted to reflect
any increase in cost resulting from such required change. To the extent any
change, deletion or addition required by any governmental authority in
connection with obtaining any governmental permit or approval increases the
Improvement Cost Budget above the Allowance, Tenant shall pay to Landlord
such increase above the Allowance in accordance with the provisions of
paragraph 5(c) of this Exhibit C. Failure to obtain any required governmental
approval or permit for the Tenant Improvements desired by Tenant shall in no
way be cause for Tenant to terminate the Lease or any amendment to the Lease.

     8.    TENANT CAUSED DELAYS:

           If substantial completion of the Tenant Improvements is delayed
due in any respect to Tenant's acts or omissions, or the acts or omissions of
Tenant's employees, contractors or agents, including, without limitation,
Tenant's failure to meet the schedule set forth in paragraph 3 of this
Exhibit C, or due to construction delays related to any changes required by
Tenant, or due to any other failure by Tenant to perform its obligations
under this Exhibit C or otherwise under the Lease, then any such

<PAGE>

delays shall be deemed "Tenant caused delays" for all purposes, including,
without limitation, determining (i) the date of substantial completion of the
Tenant Improvements (as provided in paragraph 9 below) and (ii) the
commencement date of the Lease as specified in paragraph 2(b) of the Lease.

     9.    SUBSTANTIAL COMPLETION:

           The term "substantial completion" with respect to the Tenant
Improvements shall mean the Tenant Improvements have been constructed in
substantial conformity with the Final Construction Documents (subject to
Punch List items as specified in Paragraph 10 below); provided, however, if
substantial completion of the Tenant Improvements is prevented or delayed by
Tenant in any way, including without limitation, the Tenant caused delays
described in Paragraph 8 above, then the Tenant Improvements shall be deemed
substantially complete as of the date that the Tenant Improvements would have
been substantially completed but for such Tenant caused delay.

     10.   PUNCH LIST:

           Within ten (10) business days after commencement of the term,
Tenant shall deliver to Landlord a list of items ("Punch List") that Tenant
believes Landlord should complete or correct in order for the Premises to be
acceptable. Landlord shall commence to complete or correct the items as soon
as possible, except those items that Landlord contends are not justified. If
Tenant does not deliver the Punch List to Landlord within the ten (10) day
period, Tenant shall be deemed to have accepted the Premises and approved the
construction. Nothing in this paragraph 10 shall delay the commencement of
the term or Tenant's obligation to pay rent or to make other payments due
Landlord under the Lease.

     11.   TENANT'S DEFAULT:

           Notwithstanding any provision to the contrary contained herein, if
an event of default as described in the Lease has occurred, including,
without limitation, Tenant's failure to perform its obligations under this
Exhibit C, then (i) in addition to all other rights and remedies granted to
Landlord pursuant to the Lease, Landlord shall have the right to withhold
payment of all or any portion of the Allowance and Landlord may cause
construction of the Tenant Improvements to cease (in which case, Tenant shall
be responsible for any delay in the substantial completion of the Premises
caused by such work stoppage and such delays shall be deemed Tenant caused
delays), and (ii) all other obligations of Landlord under the terms of this
Exhibit C shall be forgiven until such time as such default is cured pursuant
to the terms of the Lease. Nothing contained herein is intended, nor shall it
be construed, to abridge, waive or adversely affect any right or remedy of
Landlord under the Lease in the event of a default by Tenant, including,
without limitation, any defaults related to Tenant's failure to perform its
obligations under this Exhibit C.

<PAGE>

     12.   ATTACHMENTS:

         All references in the Lease to Exhibit C shall be deemed to also
include Exhibit C-1 and C-_____.<PAGE>

                                                           EXHIBIT 10.2

                                    SUBLEASE

         This Sublease ("Sublease") is made this 1st day of October, 1999 by and
between Audiohighway.com, a California corporation ("Sublandlord") and Be Here
Corporation, a California corporation ("Subtenant").

         RECITALS

         A.       Sublandlord, as Tenant, is leasing from Symantec Corporation,
a Delaware corporation, ("Landlord") those certain premises located at 20300
Stevens Creek Blvd., Suite 100, Cupertino, California ("Premises") pursuant to
that certain lease dated June 14, 1999 ("Master Lease"). Subtenant acknowledges
having received and reviewed a copy of the Master Lease.

         B.       Sublandlord desires to lease to Subtenant and Subtenant
desires to lease from Sublandlord a portion of the Premises known as Suite 100B
(Refer to Exhibit B) consisting of approximately 4,968 rentable square feet (the
"Sublease Premises" as shown on Exhibit A attached hereto, on the terms and
conditions set forth in this Sublease.

         NOW, THEREFORE, the parties hereto agree as follows:

         1.       PREMISES

                  Sublandlord leases to Subtenant and Subtenant hires from
Sublandlord the Premises, together with the appurtenances thereto.

         2.       INCORPORATION OF MASTER LEASE

                  This Sublease is subject to all of the terms and conditions of
the Master Lease and Subtenant hereby accepts, assumes and agrees to perform all
the obligations of Sublandlord as Tenant under the Master Lease and all of the
terms and conditions of this Sublease (with each reference therein to Landlord
and Tenant to be deemed to refer to Sublandlord and Subtenant, respectively),
excepting only paragraphs: 4. (applies except for total sums), 5. (applies
except for total sums), 15. (applies except Subtenant to be allocated 19 parking
spaces), and 51. Subtenant shall not commit or permit to be committed on the
Sublease Premises any act or omission which shall violate any term or condition
of the Master Lease. In the event of the termination for any reason of
Sublandlord's interest as Tenant under the Master Lease, then this Sublease
shall terminate therewith without any liability of Sublandlord to Subtenant;
except that if this Sublease terminates as a result of a default of one of the
parties hereto, whether under this Sublease, the Master Lease, or both, the
defaulting party shall be liable to the non-defaulting party for all damages
suffered by the non-defaulting party resulting from such termination.

<PAGE>

         3.       TERM

                  The term of this Sublease shall be for a period of two (2)
years commencing on November 1, 1999, and ending on October 31, 2001. In the
event Sublandlord is unable to deliver possession of the Sublease Premises at
the commencement of the term, Sublandlord shall not be liable for any damage
caused thereby, nor shall this Sublease be void or voidable nor shall the term
hereof be extended by such delay; provided, however, that Subtenant shall not be
liable for rent until such time as Sublandlord offers to deliver possession of
the Sublease Premises to Subtenant.

         4.       USE

                  Subtenant shall use the Sublease Premises for general office
and for no other purpose.

         5.       RENTAL

                  (a)      Subtenant shall pay to Sublandlord as rent for the
Sublease Premises, in advance, on the first day of each calendar month of the
term of this Sublease, without deduction, offset, prior written notice or
demand; in lawful money of the United States, the sums defined below.

<TABLE>
<CAPTION>
                  Rental Schedule:

                  Months                Monthly Rent                   Rate/RSF/Month
                  ------                ------------                   --------------
                  <S>                   <C>                            <C>
                  01 - 12               $14,655.60 NNN                 $2.95 NNN
                  13 - 24               $15,241.82 NNN                 $3.07 NNN
</TABLE>

If the commencement and/or termination date is not the first day of the month, a
prorated monthly installment shall be paid at the then current rate for the
fractional month during which the Sublease commences and/or terminates.

                  (b)      Sublandlord acknowledges receipt from Subtenant, on
the execution hereof, of the sum of eighteen thousand two hundred thirty two and
56/100 dollars ($18,232.56) to be applied against rent and expenses (refer to
Paragraph 5 of the Master Lease) for the first full month of the term.

                  (c)      Concurrently with Subtenant's execution of this
Sublease, Subtenant shall deposit with Sublandlord the sum of thirty seven
thousand fifty one and 34/100 dollars ($37,051.34) as a non-interest bearing
security deposit for Subtenant's performance under this Sublease. Delinquent
rent payments may be deducted from the Security Deposit. In the event Subtenant
has performed all of the terms and conditions of this Sublease throughout the
term, the amount paid as security deposit shall be returned to Subtenant upon
Subtenant vacating the Premises, after first deducting any sums owing to
Sublandlord.

         6.       SURRENDER AT END OF TERM

                  Subtenant agrees to surrender the Sublease Premises on
expiration or earlier termination of the term hereof, in good condition and
repair, reasonable wear and tear expected.

<PAGE>

         7.       LANDLORD'S WRITTEN CONSENT

                  This Sublease is conditioned upon and effective only upon
obtaining the written consent of Landlord.

         8.       NOTICES

                  All notices and demands of any kind required to be given by
Sublandlord or Subtenant hereunder shall be in writing and effective twenty-four
(24) hours after depositing same in the United States mail, postage prepaid, and
addressed to Sublandlord or Subtenant, as the case may be, at the address set
forth below their respective signature or at such other address as they may
designate from time to time.

         9.       INSURANCE

                  Insurance requirements pertaining to Sublandlord as Tenant
under paragraph 11 of the Master Lease shall also apply to Subtenant.

         10.      SIGNAGE

                  Subtenant will reasonably cooperate with Sublandlord in
obtaining signage rights from the Master Lessor. Subtenant will not be able to
utilize the monument sign for the Building.

SUBLANDLORD:                             SUBTENANT:

Audiohighway.com                         Be Here Corporation
a California corporation                 a California Corporation

By:     /s/ Nathan Schulhot              By:    /s/ Edward C. Driscoll, Jr.
   -------------------------------          ---------------------------------

Name:  Nathan Schulhot                   By:    EDWARD C. DRISCOLL, JR.
     -----------------------------          ---------------------------------

Title:  President                        By:    President
      ----------------------------          ---------------------------------

Date:   10/20/99                         Date:  10-6-99
     -----------------------------            -------------------------------

By:                                      By:
   -------------------------------          ---------------------------------

Name:                                    Name:
     -----------------------------            -------------------------------

Title:  Secretary                        Title:    Secretary
      ----------------------------             ------------------------------

Date:                                    Date:
     -----------------------------            -------------------------------

<PAGE>

CONSENT OF MASTER LANDLORD:

Master Landlord hereby consents to all terms of this Sublease.

MASTER LANDLORD:

Symantec Corporation
a Delaware corporation

By:     /s/ John B. Sorci, Jr.
   -----------------------------------------------

Name: John B. Sorci, Jr.
     ---------------------------------------------

Title:  V.P. Worldwide Logistics & Facilities
      --------------------------------------------

Date:   Oct 28, 1999
     ---------------------------------------------

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00007-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00007-of-00352.parquet"}]]