Document:

Exhibit

Exhibit 10.6

SEVENTH AMENDMENT

THIS SEVENTH AMENDMENT (this "Amendment") is made and entered into as of November
23, 2015, by and between RAR2-CLEARVIEW BUSINESS PARK OWNER, LLC, a Delaware limited liability company ("Landlord"), and GOPRO, INC., a Delaware corporation ("Tenant").

RECITALS

A.      Landlord (as successor in interest to Locon San Mateo, LLC, a Delaware limited liability company)  and Tenant (formerly known as Woodman Labs, Inc., a Delaware corporation,  successor in interest  to Woodman Labs, Inc., a California corporation) are parties to that certain Office Lease Agreement dated November 1, 2011 (the "Original Lease"), as amended by that ce1iain First Amendment to Office Lease Agreement, fully executed on or about August 29, 2012  (the "First Amendment"), that certain Second Amendment to Office Lease Agreement, dated as of September 11, 2012 (the "Second Amendment"), that certain Third Amendment  to Office Lease Agreement, fully executed on or about September 17, 2012 (the "Third Amendment"), that certain  Fourth  Amendment to Office Lease Agreement dated as of March 5, ,2013 (the "Fourth Amendment"), that certain Fifth Amendment to Office Lease Agreement dated  as  of August 20,  2013 (the "Fifth Amendment"), and that certain Sixth Amendment to Lease dated December 19, 2014 (the "Sixth Amendment") (collectively, the "Lease"). Pursuant to the Lease, Landlord has leased to Tenant space totaling 182,954 rentable square feet (the "Original Premises") currently containing (i)  45,435 rentable square feet comprising the entire building located at 3000E Clearview Way, San Mateo, California ("Building E"), and (ii) 37,222 rentable square feet comprising the entire building located at 3000F Clearview Way, San Mateo, California ("Building F"), and (iii) 9,666 rentable square feet comprised of (A) 1,728 rentable square feet known as Suite C (formerly known  as the marketing suite) on the first floor of the building commonly known as Building A located at 3155 Clearview Way, San Mateo, California ("Building A") pursuant to the First Amendment, and (B) 7,938 rentable square feet known as Suite A (formerly known as the shell space) on the first floor  of Building A; and (iv) 4,810 rentable square feet known as Suite B located on the first floor of Building A, and (v) 1,342 rentable square feet known as Suite D located on the first floor of Building A pursuant to the Fourth Amendment, and (vi) 16,674 rentable square feet known as Suite 200 on the second floor of Building A pursuant to the Second Amendment, and (vii) 860 rentable square feet described as the lobby area of Building A pursuant to the Fifth Amendment; and (viii) 66,945 rentable square feet comprising the entire building located at 3125 Clearview Way, San Mateo, California ("Building B") pursuant to the Sixth Amendment (Building A, Building B, Building E and Building F are collectively referred to herein as the "Buildings"). The Buildings are a part of the property commonly known as Clearview Business Park (the "Property").

		
	B. 
	In addition, Tenant is in possession of 17,364 rentable square feet of space known as Suite 300 in Building A (the "Sublease Space") pursuant to the terms of that certain Sublease dated June _, 2013, between Akamai Technologies, Inc., a Delaware corporation ("Akamai"), and Tenant (collectively, the "Sublease"), which Sublease is scheduled to expire by its own terms on October 15, 2018. Akamai, as tenant, and Landlord's predecessor in interest, Locon San Mateo, LLC, a Delaware limited liability company, as landlord,  are parties to that certain lease agreement  dated as of July 15, 2010 (as the same may have been amended, the "Akamai Master Lease"), governing the Sublease Space and the Akamai Master Lease shall expire by its own terms on October 31, 2018.

{2011-9599/00572913;8}

		
	C. 
	Tenant has requested that additional space containing approximately 110,876 rentable square feet comprising the entire building to be built by Landlord and which will be commonly known as Building D located at 3025 Clearview Way, San Mateo, California ("Building D"), as shown on Exhibit A attached hereto (the "Building D Expansion Space"), be added to the Original Premises and that the Lease be appropriately amended and Landlord is willing to do the same on the following terms and conditions.

		
	D. 
	Tenant has further requested that the Sublease Space be made a part of the "Premises" under the Lease and the term therefor be extended.

		
	E. 
	The Lease with respect to the Original Premises is scheduled to expire by its terms on February 15, 2019 ("Original 

Premises Prior Termination Date"), and the parties desire to extend the Term of the Lease with respect to the Original Premises, all on the following terms and conditions.

NOW, THEREFORE, in consideration of the mutual covenants and agreements herein contained and other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, Landlord and Tenant agree as follows:

		
	1.
	Building D Expansion. Effective as of the Building D Expansion Effective Date (defined below), the Original Premises is increased from approximately 182,954 rentable square feet to approximately 293,830 by the addition of the Building D Expansion Space, and from and after the Building D Expansion Effective Date, the Original Premises and the Building D Expansion Space, collectively, shall be deemed the "Premises", as defined in the Lease and as used herein. The Term for the Building D Expansion Space shall comnence on the Building D Expansion Effective Date and end on the Building D Termination Date (as defined in Section 2 below). The Building D Expansion Space is subject to all the terms and conditions of the Lease except as expressly modified herein and except that Tenant shall not be entitled to receive any allowances, abatements or other financial concessions granted with respect to the Original Premises unless such concessions are expressly provided for herein with respect to the Building D Expansion Space.

		
	1.1
	Building D Delivery. Subject to the terms and conditions of this  Amendment, the "Building D Expansion Effective Date" shall be one hundred twenty (120) days from the date upon which Landlord delivers the Building D Expansion Space to Tenant with the Landlord Work (as defined in Section 9 below and further defined in Exhibit B attached hereto) in the Building D Expansion Space substantially completed (the "Building D Delivery Date"), which is estimated to be October 1, 2016 (the "Building D Target Delivery Date"); provided, however, that if Landlord shall be delayed in substantially completing the Landlord Work in the Building D Expansion Space as a result of the occurrence of a Tenant Delay (defined below) or any events of force majeure (including without limitation, any matters  outside Landlord's reasonable control), then, for purposes of determining the Building D Delivery Date, the date of substantial completion shall be deemed to be the day that the Landlord Work would have been substantially completed absent any such event of force majeure or any Tenant Delay(s). A "Tenant Delay" means any act or omission of Tenant or its agents, employees, vendors or contractors that delays substantial  completion of the Landlord Work, including, without limitation, the  following:

		
	1.1.1
	Tenant's failure to furnish information or approvals within any time period specified in the Lease or this Amendment, including the failure to prepare or approve preliminary or final plans by any applicable due date;

		
	1.1.2
	Tenant's selection of equipment or materials that have long lead times after first being informed by Landlord that the selection may result in a delay;

		
	1.1.3
	Changes requested or made by Tenant to previously approved plans and specifications;

		
	1.1.4
	The performance of work in the Building D Expansion Space by Tenant or Tenant's contractor(s) during the performance of the Landlord Work; or

		
	1.1.5
	If the performance of any portion of the Landlord Work depends on the prior or simultaneous performance of work by Tenant, a delay by Tenant or Tenant's contractor(s) in the completion of such work.

Notwithstanding the foregoing, if Landlord fails to notify Tenant of any Tenant Delay within 2 days after the date Landlord knew of such Tenant Delay, Tenant shall not be responsible for any such Tenant Delay with respect to the period of time commencing 3 days after the date when Landlord knew that such Tenant Delay existed and ending on the date that Landlord notified Tenant of such Tenant Delay.

The Landlord Work shall be deemed to be substantially completed and the Delivery Date shall be deemed to have occurred on the date that Landlord's architect reasonably determines that all Landlord Work has been performed (or would have been performed absent any Tenant Delays or events of force majeure (as described in Section 1.2 below)), other than any details of construction, mechanical adjustment or any other matter, the noncompletion of which does not materially and unreasonably interfere with Tenant's work (as expressly permitted in this Amendment) in the Building D Expansion Space. Subject to Section 1.2 below, the adjustment of the Building D Delive1y Date and, accordingly, the postponement of Tenant's obligation to pay rent on the 

Building D Expansion Space shall be Tenant's sole remedy and shall constitute full settlement of all claims that Tenant might otherwise have against Landlord by reason of the Building D Expansion Space not being ready for the Building D Delivery Date on the Building D Target Delivery Date.

A preliminary construction schedule outlining basic benchmarks for the completion of the Landlord Work is attached hereto as Exhibit B-2.

		
	1.2
	Outside Building D Delivery Date. If the Building D Delivery Date has not occurred on or before January 31, 2017 (the "Outside Building D Delivery Date"), Tenant shall be entitled to a rent abatement following the Building D Expansion Effective Date of$14,229.09 for every day in the period beginning on the Outside Building D Delivery Date and ending on the Building D Delivery Date. Notwithstanding the foregoing, if the Building D Delivery Date has not occurred on or before September 30, 2017 (the "Required Building D Delivery Date") solely due to a delay caused by Landlord and within Landlord's reasonable control, Tenant, as its sole remedy, may terminate this Amendment by giving Landlord written notice of termination on or before the earlier to occur of: (i) ten (10) business days after the Required Building D Delivery Date; and (ii) the Building  D Delive1y  Date. In  such event, this Amendment shall be deemed null and void and of no further force and effect and Landlord shall promptly refund any prepaid rent and Security Deposit previously advanced by Tenant under this Amendment and, so long as Tenant has not previously defaulted under any of its obligations pursuant to Exhibit C hereto, which default remains uncured, the parties hereto shall have no further responsibilities or obligations to each other with respect to the Building D Expansion Space as set forth in this Amendment. Landlord and Tenant acknowledge and agree that: (i) the determination of the Building D Delivery Date shall take into consideration the effect of any Tenant Delays by Tenant; and (ii) the Outside Building D Delivery Date and the Required Building D Delivery Date shall be postponed by the number of days the such date is delayed due to any delays in obtaining permits or other governmental approvals, strikes, acts of God, shortages of labor or materials, war, terrorist acts, civil disturbances and other causes beyond the reasonable control of Landlord (as used herein, events of "force majeure").

		
	1.3
	Building D Delivery Date. Commencing on the Building D Delive1y Date, Tenant shall be permitted to enter the Building D Expansion Space as of the Building D Delivery Date to perform the Tenant Work described in Exhibit C attached hereto (the "Tenant's Construction Period"). During the Tenant's Construction Period, Tenant shall comply with all terms and provisions of the Lease, except those provisions requiring payment of Base Rent or Tenant's Share of Expenses and Taxes as to the Building D Expansion Space. If Tenant takes possession of the Building D Expansion Space prior to the Building D Expansion Effective Date for any reason whatsoever  (other than the performance of work in the Building D Expansion Space, including the installation of furniture, fixtures, equipment, and wiring and cabling, with Landlord's prior approval, which approval shall not be unreasonably withheld), such possession shall be subject to all the terms and conditions of the Lease and this Amendment, and Tenant shall pay Base Rent and Tenant's Share of Expenses and Taxes as applicable to the Building D Expansion Space to Landlord on a per diem basis for each day of occupancy prior to the Building D Expansion Effective Date.

		
	1.4
	Early Access. In the event Landlord reasonably determines that the Landlord Work in Building D has sufficiently progressed so that Tenant's access to the Premises shall not adversely impact Landlord's construction of the Landlord Work and that Tenant may commence preparations for and the initial construction of the Tenant Work in Building D prior to the Building D Delive1y Date, at such time Landlord may grant Tenant the right to enter the Premises prior to the Building D Delivery Date for the purposes described in this Section. Such early access shall be at Tenant's sole risk and solely for the purpose of comnencing the Tenant Work in a manner that does not interfere with the Landlord Work. Landlord may withdraw such permission to enter the Premises prior to the commencement of Tenant's Construction Period at any time that Landlord reasonably determines that such entry by Tenant is causing a dangerous situation for Landlord, Tenant or their respective contractors or employees, or if Landlord reasonably determines that such entry by Tenant is hampering or otherwise preventing Landlord from proceeding with the completion of the Landlord Work at the earliest possible date. In the event Landlord grants such access to Tenant more than thirty (30) days prior to the Building D Deliver Date (the  number of days in excess of such fourteen (14) day period shall be referred to herein as the "Acceleration Period"), the Building D Expansion Effective Date shall be accelerated to an earlier date by the number of days of the Acceleration Period, if any.

		
	1.5
	Fire Sprinkler Quarterly Maintenance. Landlord shall be responsible for the repair and maintenance of the fire life safety systems servicing the Building D Expansion Space and  the costs thereof shall be included in 

Expenses.

		
	1.6
	Tenant's Security System. Subject to any applicable laws, rules, statutes, regulations, codes or other such requirements, inspection requirements, and the terms and conditions of the Lease (as amended), Tenant shall have the nonexclusive right to install an internal security system (Tenant's "Security System") within the Building D Expansion Space  so long as such Security System in no event affects or otherwise impacts the functionality, structural integrity or operability of any Building system or the structure of the Building. The terms and conditions of the Lease regarding the installation (the "Security System Installation"), maintenance, repair and removal of any Premises Improvements shall govern such installation and removal by Tenant of the Security System (except as expressly provided herein). The Security System Installation shall be performed by contractors reasonably approved by Landlord (which approval shall not be unreasonably withheld), at Tenant's sole cost and expense. Landlord may, at its election by providing written notice to Tenant and at Tenant's sole cost and expense, elect to perform the Security System Installation. The size and design of such Security System shall be subject to Landlord's prior written approval which approval shall not be unreasonably withheld, conditioned or delayed. Tenant shall be responsible, at its sole cost and expense, for maintaining and repairing Tenant's Security System in first class condition and repair. Notwithstanding  anything to the contrary contained in the Lease,  as amended, Tenant shall remove Tenant's Security System (and restore the Building to the condition existing prior to the installation, operation and removal thereof, subject to normal wear and tear) prior to the expiation or earlier termination of the Lease with respect to Building D unless Landlord otherwise notifies Tenant in writing no later than thirty (30) days prior to the expiration or earlier termination of the term of the Lease with respect to Building D. So long as Landlord does not require the Security System to be removed pursuant to the terms hereof, upon expiration or earlier termination of the Lease, title to the Security System shall pass to Landlord. Notwithstanding anything to the contrary, Landlord shall not directly or indirectly be liable to Tenant or any other person and Tenant hereby waives any and all claims against and releases Landlord and the Landlord Indemnities from any and all claims arising as a consequence of or related to Tenant's Security System, or the failure thereof. The terms of this Section 1.6 are personal to Tenant initially named in this Amendment.

		
	1.7
	Remeasurment. The parties hereby stipulate that the Building D Expansion Space contains  the number of rentable square feet set forth in Recital C, and recognize that such square footage includes the allocation of certain Common Areas on a propo1iionate basis in accordance with the Building Owners and Managers Association International Standard Method for Measuring Floor Area in Office Building, ANSI Z65.1-1996, Method B and accompanying guidelines (the "BOMA Standard"). Notwithstanding the foregoing agreement with respect to the square footage of the Building D Expansion Space, Tenant shall have the right, by giving Landlord written notice (the "Measurement Notice") by no later than thirty (30) days after the Building D Delivery Date (the "Confirmation Period"), to cause Tenant's architect for the Tenant Work to remeasure the Building D Expansion Space in accordance with the BOMA Standard. In the event that Tenant provides Landlord with written notice ("Square Footage Notice") within the thirty (30) days after Tenant's delivery of the Measurement  Notice, that the remeasurement of the Building D Expansion

Space by Tenant's architect in accordance with the BOMA Standard has produced a rentable square footage number that is in excess of or lower than the rentable square footage number prepared by Landlord, and if Landlord does not dispute such remeasurement, any payments due to Landlord from Tenant based upon the number of rentable square feet contained in the Building D Expansion Space shall be proportionally, retroactively and prospectively reduced or increased, as appropriate, to reflect the actual number of rentable square feet, as properly remeasured under the BOMA Standard and the Base Rent, Tenant's proportionate share and any payments due from Landlord to Tenant (e.g., the Building D Allowance) shall be similarly prop01tionally, retroactively and prospectively reduced or increased, as appropriate, to reflect the actual number of rentable square feet, as properly remeasured under the BOMA Standard. Tenant's failure to deliver  the Square Footage Notice prior to expiration of the Confinnation Period, shall be deemed to constitute Tenant's acceptance of the square footage stated in this Amendment. If Landlord disagrees with Tenant's remeasurement and if a dispute occurs regarding the final accuracy of such measurements, Landlord and Tenant shall agree upon a mutually acceptable architect to remeasure the Building D Expansion Space in accordance with the BOMA Standard and the determination of such architect shall be binding upon Landlord and Tenant. The cost of such mutually agreed architect shall be shared equally by Landlord and Tenant. Until such determination is made by the mutually selected architect, the patties shall utilize the square footage figure stated in this Amendment; thereafter, the parties shall make the appropriate retroactive adjustments. Notwithstanding the foregoing language or anything to the contrary contained herein or in the Lease, for  purposes of this 

Amendment, in no event shall the rentable square footage of the Building D Expansion Space be less than or greater than two percent (2%) of number of rentable square feet for the set forth in Recital C above. If pursuant to this Section 1.7 the rentable square footage of the Building D Expansion Space shall be adjusted, within ten (10) business days after such new determination, Landlord and Tenant shall confirm the same in writing by entering into a mutually acceptable amendment of the Lease modifying the rentable square footage of the Building D Expansion Space, Base Rent, Tenant's Share, the Building D  Allowance, and any other matters set forth in this Amendment  affected by  such change in the rentable square footage of the Building D Expansion Space.

		
	2.
	Building D Expansion Space Term. The Term of the Lease for the Building D Expansion Space only shall terminate one hundred and twenty (120) months from the Building D Expansion Effective Date (the "Building D Termination Date"), unless sooner terminated in accordance with the terms of the Lease, as amended. That portion of the Term commencing on the Building D Expansion Effective Date and ending on the Building D Termination Date shall sometimes be referred to herein as the "Building D Term."

		
	3.
	Sublease Space Expansion. Effective as of the expiration or earlier termination of the Sublease or the Akami Master Lease, as the case may be (the "Sublease Space Expansion Effective Date"), the Premises, as increased in Section 1 above, is further increased from approximately 293,830 rentable square feet to approximately 311,194 rentable square feet by the addition of the Sublease Space and from and after the Sublease Space Expansion Effective Date, the Original Premises, the Building D Expansion Space and the Sublease Space, collectively, shall be deemed the "Premises", as defined in the Lease, and as used herein (provided that the foregoing shall be adjusted in the event of any delay in the Building D Expansion Effective Date beyond the Sublease Space Expansion Effective Date). For purposes of this Amendment only, the Original Premises and the Sublease Space (but  excluding the Building D Expansion  Space) may collectively be referred to herein as "The Campus." The Term for the Sublease Space shall commence on the Sublease Space Expansion Effective Date and end on the Original Premises Extended Te1mination Date (defined below) unless sooner terminated in accordance with the terms of the Lease, as amended hereby. By being in possession of the Sublease Space, as of the date hereof, Tenant shall be deemed to have accepted possession of the Sublease Space in its "as is" condition and configuration pursuant to the Lease, as amended hereby. Tenant agrees that the Sublease Space is in good order and satisfactory condition, and that there are no representations or warranties by Landlord regarding the condition of the Sublease Space or Building A. Landlord hereby agrees that Tenant may  postpone any removal and restoration requirements Tenant may have under the Sublease, if any, with respect to the Sublease Space until the expiration or earlier termination of the Lease, as amended hereby, provided that the foregoing shall in no way waive Landlord's  rights to  enforce such removal and restoration obligations upon the expiration or earlier termination of the Lease, as amended hereby. From and after the Sublease Space Expansion Effective Date, the Sublease Space is further subject to all the terms and conditions of the Lease except as expressly modified herein and except that Tenant shall not be entitled to receive any allowances, abatements or other financial concessions granted with respect to the Premises unless such concessions are expressly provided for herein with respect to the Sublease Space.

		
	4.
	Original Premises Extension. The Term of the Lease with respect to the Original Premises is hereby extended for a period of sixty (60) months and shall expire on February 14, 2024 ("Original Premises Extended Termination Date"), unless sooner terminated in accordance with the terms of the Lease. That portion of the Term commencing the day immediately following the Original Premises Prior Termination Date ("Original Premises Extension Date") and ending on  the  Original Premises Extended Termination Date shall be referred to herein as the "Original Premises Extended Term."

		
	5.
	Base Rent.

		
	5.1
	Original Premises Through Prior Original Premises Termination Date. The Base Rent, Tenant's Share of Expenses and Taxes and all other charges under the Lease shall be payable as provided therein with respect to the Original Premises through and including the Original Premises Prior Termination Date.

		
	5.2
	Original Premises From and After Original Premises Extension Date. As of the  Original Premises Extension Date, the schedule of Base Rent payable with respect to the Original Premises during the Original Premises Extended Term is the  following:

	
				
	Period
	Rentable Square Footage
	Monthly Rate Per Square Foot
	Monthly Base Rent

	2/15/19 -2/14/20
	182,954
	$3.30
	$603,748.20

	2/15/20 -2/14/21
	182,954
	$3.40
	$622,043.60

	2/15/21 -2/14/22
	182,954
	$3.50
	$640,339.00

	2/15/22 -2/14/23
	182,954
	$3.61
	$660,463.94

	2/15/23 -2/14/24
	182,954
	$3.72
	$680,588.88

All such Base Rent shall be payable by Tenant in accordance with the terms of the Lease, as amended hereby.

* Notwithstanding anything in the Lease to the contrary, so long as Tenant is not in default under the Lease, as amended hereby, Tenant shall be entitled to an abatement of Base Rent with respect to the Original Premises in the amount of $603,748.20 per month for the first six (6) full calendar months following the Original Premises Extension Date. The maximum total amount of Base Rent abated with respect to the Original Premises in accordance with the foregoing shall equal $3,622,489.20 (the "Original Premises Abated Base Rent"). Provided, however, Tenant, by providing written notice to Landlord, may elect to apply the Original Premises Abated Base Rent toward Base Rent applicable to the Original Premises and due hereunder during the calendar year 2019 so long as the amount of such abatement does not exceed the Original Premises Abated Base Rent as set forth in this paragraph. If Tenant defaults under the Lease, as amended hereby, at any time during the Original Premises Extended Term and fails to cure such default within any applicable cure period under the Lease, and the Lease is thereafter terminated in connection with such default, then all Original Premises Abated Base Rent shall immediately become due and payable. In addition to the foregoing, if Tenant defaults under the Lease, then Tenant's right to receive the Abated Base Rent shall toll (and Tenant shall be required to pay Base Rent during such period of any Tenant default) until Tenant has cured such default and at such time Tenant shall be entitled to receive any unapplied Abated Base Rent until fully applied. Only Base Rent shall be abated pursuant to this paragraph, as more particularly described herein, and Tenant's Share of Expenses and Taxes and all other rent and other costs and charges specified in the Lease, as amended hereby, shall remain as due and payable pursuant to the provisions of the Lease, as amended hereby.

		
	5.3 
	Building D Expansion Space From Building D Expansion Effective Date Through Extended Termination Date. As of the Building D Expansion Effective Date, the schedule of Base Rent payable with respect to the Building D Expansion Space during the Building D Term is the following:

	
				
	Months
	Rentable Square Footage
	Monthly Rate Per Square Foot
	Monthly Base Rent

	B.D.E.E.D. * - 12
	110,876
	$3.85
	$426,872.60**

	13 -24
	110,876
	$3.97
	$440,177.72

	25 -36
	110,876
	$4.09
	$453,482.84

	37 - 48
	110,876
	$4.21
	$466,787.96

	49 -60
	110,876
	$4.34
	$481,201.84

	61 -72
	110,876
	$4.47
	$495,615.72

	73 -84
	110,876
	$4.60
	$510,029.60

	85 -96
	110,876
	$4.74
	$525,552.24

	97 - 108
	110,876
	$4.88
	$541,074.88

	109 -120
	110,876
	$5.03
	$557,706.28

All such Base Rent shall be payable by Tenant in accordance with the terms of the Lease, as amended hereby.

* "B.D.E.E.D." as set forth above means "Building D Expansion Effective Date." At such time when the Building D Expansion Effective Date has been determined, Landlord shall prepare a memorandum agreement setting forth the actual Building D Expansion Effective Date, the Building D Termination Date and, if necessary, a revised rent schedule.

Should Tenant fail to execute and deliver such memorandum to Landlord within thirty (30) business days after Landlord's request, the information set forth in such memorandum provided by Landlord shall be conclusively presumed to be agreed and correct.

** Notwithstanding anything in the Lease to the contrary, so long as Tenant is not in default under the Lease, as amended hereby, Tenant shall be entitled to an abatement of Base Rent with respect to the Building D Expansion Space in the amount of $426,872.60 per month for the first seven (7) full calendar months following the Building D Expansion Effective Date. The maximum total amount of Base Rent abated with respect to the Building D Expansion Space in accordance with the foregoing shall equal $2,988,108.20 (the "Building D Abated Base Rent"). If Tenant defaults under the Lease, as amended hereby, at any time during the Building D Term and fails to cure such default within any applicable cure period under the Lease, and the Lease is thereafter terminated in connection with such default, then all Building D Abated Base Rent shall immediately become due and payable. In addition to the foregoing, if Tenant defaults under the Lease, then Tenant's right to receive the Abated Base Rent shall toll (and Tenant shall be required to pay Base Rent during such period of any Tenant default) until Tenant has cured such default and at such time Tenant shall be entitled to receive any unapplied Abated Base Rent until fully applied. Only Base Rent shall be abated pursuant to this paragraph, as more particularly described herein, and Tenant's Share of Expenses and Taxes and all other rent and other costs and charges specified in the Lease, as amended hereby, shall remain as due and payable pursuant to the provisions of the Lease, as amended hereby.

		
	5.4
	Sublease Space From the Sublease Space Expansion Effective Date Through Extended Termination Date. As of the Sublease Space Expansion Effective Date, the schedule of Base Rent payable with respect to the Sublease Space for the balance of the original Term and the Original Premises Extended Term is the following:

	
				
	Period
	Rentable Square Footage
	Monthly Rate Per Square Foot
	Monthly Base Rent

	Sublease Space Expansion Effective Date - 2/14/20
	17,364
	$3.30
	$57,301.20

	2/15/20 -2/14/21
	17,364
	$3.40
	$59,037.60

	2/15/21 -2/14/22
	17,364
	$3.50
	$60,774.00

	2/15/22 -2/14/23
	17,364
	$3.61
	$62,684.04

	2/15/23 -2/14/24
	17,364
	$3.72
	$64,594.08

All such Base Rent shall be payable by Tenant in accordance with the terms of the Lease,  as amended hereby.

*Notwithstanding anything in the Lease to the contrary, so long as Tenant is not in default under the Lease, as amended hereby, Tenant shall be entitled to an abatement of  Base Rent with respect to the Sublease Expansion Space in the amount of $57,301.20 per month for the first six (6) full calendar months following the Original Premises Extension Date. The maximum total amount of Base Rent abated with respect to the Sublease Expansion Space in accordance with the foregoing shall equal $343,807.20 (the "Sublease Space Abated Base Rent"). Provided,  however,  Tenant may elect to apply the Sublease Space Abated Base Rent toward Base Rent applicable to the Sublease Space and due hereunder during the calendar year 2019 so long as the amount of such abatement does not exceed the Sublease Space Abated Base Rent as set forth in this paragraph. If Tenant defaults under the Lease, as amended  hereby, at any time during the Original Premises Extended Term and fails to cure such default within any applicable cure period under the Lease, and the Lease is thereafter  terminated  in connection  with  such default, then all Sublease Space Abated Base Rent  shall  immediately  become  due and payable. In addition to the foregoing, if Tenant defaults  under  the  Lease,  then  Tenant's right to receive the Abated Base Rent shall toll (and Tenant shall be required to  pay Base Rent during such period of any Tenant default) until Tenant  has cured  such default and at such time Tenant shall be entitled to receive  any unapplied  Abated Base  Rent until fully applied. Only Base Rent shall be abated  pursuant  to this paragraph,  as  more particularly described herein, and Tenant's Share of Expenses  and  Taxes  and  all other rent and other costs and charges specified in the Lease, as amended hereby, shall remain as due and payable pursuant to the provisions  of the Lease, as amended hereby.

*At such time when the Sublease Space Expansion Effective Date has been determined, Landlord shall prepare a memorandum agreement setting forth the actual Sublease Space Expansion Effective Date 

and, if necessary, a revised rent schedule. Should Tenant fail to execute and deliver such memorandum to Landlord within thirty (30) days after Landlord's request, the information set forth in such memorandum provided by Landlord shall be conclusively presumed to be agreed and correct.

		
	5.5
	Landlord's Buy-Out Option. The Original Premises Abated Base Rent, and  the  Building D Abated Base Rent and the  Sublease  Space  Abated  Base  Rent  shall collectively be referred to herein as the "Abated Base Rent."  Notwithstanding  anything to the contrary set forth in the Lease or this Amendment, Landlord  and  Tenant  hereby agree that Landlord shall have the option (the "Buy-Out Option") to require Tenant to  pay to Landlord all or any portion  of any Abated Base Rent then remaining  and allocable  to Tenant pursuant to the terms and conditions of this Amendment as of the date of Landlord's Buy-Out Notice (defined below) as and when rent is payable pursuant to the Lease, subject to the terms and conditions set forth below.  To  exercise Landlord's  Buy­ Out Option, Landlord shall (i) provide written notice to Tenant of such exercise (the "Buy-Out Notice") at any time prior to the date all Abated Base Rent has been applied under the terms of the Amendment (which Buy-Out Notice shall specify the date as of  which Tenant shall be required to pay  the Base Rent  that  was  otherwise  abated  pursuant to this Section 5 above, provided that  such date  shall in no  event be  less  than ten  (10) days after the date the Buy-Out  Notice  is tendered  by Landlord),  and  (ii) pay to Tenant  an amount equal to the Abated Rent Purchase Price (as defined below). In the event Landlord exercises its Buy-Out Option, then notwithstanding anything to the contrary set forth in this Section 5, effective as of the date specified  in Landlord's  Buy-Out  Notice, Base Rent with respect to the Premises to the extent stated in Landlord's Buy-Out Notice shall no longer be abated pursuant to this Section 5 and  shall be  due  and  payable  by Tenant in accordance with this Amendment  and  the  Lease.  The  amount  of Base  Rent that Tenant is not obligated to pay or will not be obligated to pay  with  respect  to the  portion of the period remaining  during which Tenant is entitled to abated rent  as set forth  in this  Section 5 as of the date of Landlord's Buy-Out Notice  shall be sometimes referred  to hereafter as a "Remaining Abated Rent Amount." As used herein, "Abated Rent Purchase  Price" shall mean the present  value  of the Remaining  Abated  Rent   Amount  that is then remaining as of the date of Landlord's Buy-Out  Notice,  discounted  at  an annual discount  rate  equal to five percent  (5%).  In the event  Landlord  elects to  exercise its Buy-Out Option, the Abated Rent Purchase  Price  shall be paid  on or prior to the date  set forth in the Buy-Out Notice for Tenant's payment of Base Rent. Notwithstanding the foregoing, Landlord shall have the right, at any time following delivery of the Buy-Out Notice but prior to the payment of the Abated Rent Purchase Price, to rescind all or any portion of the Buy-Out Notice, in which event the terms of Section  5 shall continue  to  apply to the portion of abated rent so rescinded and Landlord shall have no further  obligation to pay the Abated Rent  Purchase  Price to  Tenant  hereunder.  In  addition,  in  the event that Tenant is in default at any time following Landlord's Buy-Out Notice, Landlord shall have no further obligation to pay the Abated  Rent  Purchase  Price  to  Tenant hereunder and if Tenant defaults under this Amendment or the Lease at any time during the Term and fails  to  cure  such  default within  any  applicable  cure period  under the Lease, then the Abated Rent Purchase Price paid  to  Tenant  hereunder  shall immediately become due and  payable.  Following  Tenant's  written  request,  and  at Tenant's sole cost and expense, if,  in  connection  with  Landlord's  exercise  of the  Buy­ Out Option, Tenant elects to formally contest any related applicable tax or other such assessment charged to Tenant as a result of the payment to Tenant of the Abated Rent Purchase Price, Landlord shall reasonably cooperate in good faith with  Tenant  in  its  efforts to contest any such taxes or assessment  and  in such event,  Tenant  shall within  thirty (30) days of delivery of Landlord's  written request therefor  reimburse  Landlord  for all of its reasonable and actual out of pocket costs and expenses  incurred  in connection  with such cooperation; provided however, in any event Tenant,  not  Landlord,  shall be liable for any such taxes and assessments  arising  in connection with  Tenant's receipt  of  the Abated  Rent Purchase  Price.

		
	6.
	Security Deposit. Landlord currently is holding the sum of $1,769,214.97 as a security deposit pursuant to the terms of the Lease, as amended. Provided Tenant is in compliance with the Lease, upon Tenant's execution hereof, Landlord shall return to Tenant the sum equal to the amount of the security deposit then held by Landlord under the Lease in excess of one million dollars ($1,000,000.00) estimated to be $769,214.97, and, accordingly, simultaneous with the execution hereof, the Security Deposit is decreased from $1,769,214.97 to $1,000,000.00, to be held by Landlord as provided under Article 6 of the Original Lease, as amended by Section 9.5 of the  Second Amendment and Section 6 of the Fourth Amendment, as security for payment of rent  and  the performance  of the other terms and conditions of the Lease by Tenant.

		
	7.
	Tenant's Share. For the period commencing with the Building D Expansion Effective Date and ending on the Building D Termination Date, Tenant's Share for the Building D Expansion Space is 100% of Building D and 29.30% of the Property. For the period commencing with the Sublease Space Expansion Effective Date and ending on the Original Premises Extended Termination Date, Tenant's Share for the Sublease Space is 34.24% of the Building A and 4.59% 

of the Property. Accordingly, as of the Sublease Space Expansion Effective Date Tenant's Share for the Building D Expansion Space, the Original Premises and the Sublease Space is, collectively, 82.02% of the Prope1ty.

		
	8.
	Additional Rent.

		
	8.1
	Original Premises for the Extended Term. For the period commencing with the Original Premises Extension Date and ending on the Original Premises Extended Terminatio  Date, Tenant shall pay all additional rent payable under the Lease, including Tenant's Share of Expenses and Taxes applicable to the Original Premises, in accordance with the terms of  the Lease, as amended hereby.

		
	8.2
	Sublease Space from Sublease Expansion Effective Date Through the Original Premises Extended Termination Date. For the period commencing with the Sublease Expansion Effective Date and ending on the Original Premises Extended Termination Date, Tenant shall pay all additional rent payable under the Lease, including Tenant's Share of Expenses and Tmrns applicable to the Sublease Space, in accordance with the terms of the Lease, as amended hereby.

		
	8.3
	Building D Expansion Space From Building D Expansion Effective Date Through Extended Termination Date. For the period commencing with the Building D Expansion Effective Date and ending on the Building D Termination Date, Tenant shall pay for Tenant's Share of Expenses and Taxes applicable to the Building D Expansion Space in accordance with the terms of the Lease, as amended hereby.

		
	8.4
	Expenses. Expenses for the Project (including the Original Premises, the Sublease Space and the Building D Expansion Space) shall include a management fee (as provided for in Section B.2 of Exhibit E to the Original Lease), provided, however, in no event shall Tenant's Share of the management fees for the Project (expressed as a percentage of gross receipts for the Project) exceed two and one-half percent (2.5%) of such gross receipts (provided that any period of abated rent or other such concessions shall be adjusted to full rents and other sums due at the Project for purposes of this Section 8.4  only

		
	9.
	Building Improvements.

		
	9.1
	Landlord's Responsibility for Improvements to Building D Expansion Space. Landlord shall pe1fo11n improvements to the Building D Expansion Space (the "Landlord Work") in accordance with the terms of Exhibit B attached hereto. To the extent assignable, Landlord shall assign to Tenant a right to enforce for a period of up to one (1) year the warranties and guarantees issued by the contractor who constructs the electrical, plumbing, mechanical, and heating, ventilation and air conditioning systems of the Building D Expansion Space installed as part of the Landlord Work (except to the extent such warranties and/or guaranties pertain to any repair and maintenance obligations of Landlord as set forth in the Lease, if any, and to the extent the assignment of any such right adversely impact's Landlord's rights under such warranties and/or guarantees or the overall value of such warranties and/or guarantees); provided, however, that to the extent that Tenant is prohibited by law from enforcing such warranties or guarantees, or if Tenant's enforcement of any such warranties and/or guarantees would adversely impact Landlord's rights thereunder or the overall value of such warranties and/or guarantees, Landlord shall, on Tenant's behalf and at no additional cost to Landlord, make efforts to diligently and reasonably enforce such warranties and guarantees. In the event that any of Landlord's contractors fails to respond within a reasonable period of time to Tenant's efforts to enforce any such Tenant's assigned rights under any warranty or guarantee after Tenant has  diligently pursued such enforcement, Landlord shall make commercially reasonable efforts to assist in such enforcement efforts.

		
	9.2
	Tenant's Responsibility for Improvements to Building D Expansion  Space.  Tenant shall perform improvements to the Building D Expansion Space (the "Tenant Work") in accordance with the terms of Exhibit C attached hereto and Tenant shall be entitled to an improvement allowance in connection with such work  as more  fully described  in  Exhibit C.

		
	9.3
	Tenant's Responsibility for Other Building Improvements. Tenant shall perform improvements to the Original Premises and the Sublease Space (the "Campus Tenant Work") in accordance with the terms of Exhibit C attached hereto and Tenant shall be entitled to an improvement allowance in connection with such work as more fully described in Exhibit C.

		
	10.
	Signage.

		
	10.1
	Building D Signage.

		
	10.1.1
	Subject to the terms and conditions of this Section 10, Tenant shall be entitled to one (1) tenant identification sign to be located on Building D adjacent to  the entrance and one (1) tenant identification sign located on Building D that shall be visible from Highway 92 (collectively, the "Building D Signage"). The exact location of the Building D Signage shall be subject to all applicable Laws and Landlord's prior written approval, which approval shall not be unreasonably withheld. Such right to the Building D Signage is  subject to the following terms  and conditions: (a) Tenant shall submit plans and drawings for the Building D Signage to Landlord and to the City of San Mateo and to any other public authorities having jurisdiction and shall obtain written approval from Landlord, Landlord's approval not to be unreasonably withheld, and each such jurisdiction prior to installation, and shall fully comply with all applicable Laws; (b) Tenant shall, at Tenant's sole cost and expense, design, construct  and install the Building  D Signage; (c) the size, color and design of the Building D Signage shall be subject to Landlord's prior written approval, which approval shall not be unreasonably withheld; and (d) Tenant shall maintain the Building D Signage in good condition and repair, and all costs of maintenance and repair shall be borne by Tenant. Maintenance shall include, without limitation, cleaning. Notwithstanding the foregoing, Tenant shall not be liable for any fee in connection with Tenant's right  to display the Building D Signage in accordance with the Lease. At Landlord's option, Tenant's right to the Building D Signage may be revoked and terminated upon occurrence of any of the following events: (i)  Tenant  shall  be  in default under the Lease for more than  sixty (60) days beyond  any applicable  cure  period; (ii) Tenant or an assignee following a Permitted Transfer leases less than 100% of Building D and occupies less than fifty percent (50%) of Building D; or (iii) the Lease, as amended hereby, shall terminate or otherwise no longer be in effect.

		
	10.1.2
	Upon the expiration or earlier termination of the Lease, as amended hereby, or at such other time that Tenant's signage rights are terminated pursuant to the terms hereof, if Tenant fails to remove the Building D Signage and repair the Building D in accordance with the terms of the Lease, as amended hereby, Landlord shall cause the Building D Signage to be removed from Building D and Building D to be repaired and restored to the condition which existed prior to the installation of

the Building D Signage (including, if necessary, the replacement of any precast concrete panels), ordinary wear and tear and damage due to casualty and condemnation excepted, all at the sole cost and expense of Tenant and otherwise in accordance with the Lease, as amended hereby, without further notice from Landlord. Notwithstanding anything to the contrary contained in the Lease, as amended hereby, Tenant shall pay all costs and expenses for such removal and restoration within thirty (30) days following delivery of an invoice therefor. Other than in connection with an assignment that is a Permitted Transfer, the rights provided in this Section 10.1 shall be non-transferable unless otherwise agreed by Landlord in writing in its reasonable discretion.

		
	10.2
	Monument Sign.

		
	10.2.1
	So long as (a) Tenant is not in default under the terms of the Lease for more than sixty (60) days beyond applicable notice and cure periods; (b) Tenant or an assignee following a Permitted Transfer is in occupancy of no less than fifty percent (50%) of the entire Building D Expansion Space; and (c) Tenant has not assigned the Lease or sublet the Building D Expansion Space other than in connection with a Permitted Transfer, Tenant shall have the nonexclusive right to have its name listed on the shared monument sign for Building D (the "Monument Sign"), subject to the terms of this Section 10.2. So long as Tenant leases 100% of Building D, the Monument Sign shall be exclusive to Tenant. The design, size and color of Tenant's signage with Tenant's name to be included on the Monument Sign, and the manner in which it is attached to the Monument Sign, shall comply with all applicable Laws and shall be subject to the approval of Landlord, Landlord's approval not to be unreasonably withheld, and any applicable governmental authorities. Landlord reserves the right to withhold consent to any sign that, in the reasonable judgment of Landlord, is not harmonious with the design standards of Building D and Monument Sign. Landlord shall have the right to require that all names on the Monument Sign be of the same size and style. Tenant must obtain Landlord's written consent (which consent shall not be unreasonably withheld) to any proposed signage and lettering 

prior to its fabrication and installation. To obtain Landlord's consent, Tenant shall submit design drawings to Landlord showing the type and sizes of all lettering; the colors, finishes and types of materials used; and (if applicable and Landlord consents in its sole discretion) any provisions for illumination. Although the Monument Sign will be maintained by Landlord, Tenant shall pay its proportionate share of the cost of any maintenance and repair associated with the Monument Sign. In the event that additional names are listed on the Monument Sign, all future costs of maintenance and repair shall be prorated between Tenant and the other parties listed on such Monument Sign.

		
	10.2.2
	Tenant's name on the Monument Sign shall be designed, constructed, installed, insured, maintained, repaired and removed from the Monument Sign all at Tenant's sole risk, cost and expense. Tenant, at its cost, shall be responsible for the maintenance, repair or replacement of Tenant's signage on the Monument Sign, which shall be maintained in a manner reasonably satisfactory to Landlord.

		
	10.2.3
	Upon the expiration or earlier termination of the Lease, as amended hereby, or if during the Building D Term (and any extensions thereof) (a) Tenant is in default under the terms of the Lease for more than sixty (60) days after the expiration of applicable cure periods; (b) Tenant leases less than fifty percent (50%) of the entire Building D Expansion Space; or (c) Tenant assigns the Lease (other than to a Permitted Transferee), then Tenant's rights granted herein will terminate and Landlord may remove Tenant's name from the Monument  Sign at Tenant's  sole cost and expense and restore the Monument Sign to the condition it was in prior to installation of Tenant's signage thereon, ordinary wear and tear and damage due to casualty and condemnation excepted. The cost  of  such removal  and restoration shall be payable as additional rent within thirty (30) days of Landlord's written demand accompanied by a documented invoice therefor. Landlord may, at anytime during the Term (or any extension thereof) when Tenant  is not the sole Tenant in  the Building D Expansion Space, upon five (5) days prior written notice to Tenant, relocate the position of Tenant's name on the Monument Sign. The cost of such relocation  of Tenant's name shall be at the cost and expense of Landlord.

		
	10.2.4
	The rights provided in this Section 10.2 shall be non-transferable other than to an assignee as part of a Permitted Transfer unless otherwise agreed by Landlord in writing in its sole discretion.

		
	11.
	Backup Generator.

		
	11.1
	Tenant, subject to Landlord's review and  approval  of Tenant's  plans therefor,  shall have  the right to install a 750 kW/500 gallon diesel tank kilowatt supplemental generator (the "Generator") and an above ground fuel tank (the "Tank") to provide emergency additional electrical capacity to the Building D Expansion Space during the Building D Term. Tenant's plans for the Generator and the Tank shall include a secondary containment system to protect against and contain  any release  of hazardous  materials.  The Generator and the Tank shall be placed at the location reasonably proximate to Building D, such location to be mutually and reasonably agreed to by Landlord and Tenant (the "Generator Area"). Notwithstanding the foregoing, Tenant's right  to install the  Generator  and the  Tank shall be subject to Landlord's reasonable approval of the manner in which the Generator and the Tank is installed, the manner in which any fuel pipe is installed, the manner in which any ventilation and exhaust  systems are installed, the manner  in which  any cables are run to and from the Generator to the Building D Expansion Space and the measures that will be taken to eliminate any vibrations or sound disturbances from the operation of the Generator, including, without limitation, any necessary two (2) hour rated enclosures or sound installation. Landlord shall have the right to require an acceptable enclosure to hide or disguise the existence of the Generator and the Tank and to minimize any adverse effect that the installation of the Generator and the Tank may have on the appearance of the Building D. Tenant shall be solely responsible for obtaining  all  necessary governmental and regulatory approvals and for the cost of installing, operating, maintaining and removing the Generator and the Tanlk. Tenant shall not install or operate the Generator or the Tank until Tenant has obtained and submitted to Landlord copies of all required governmental permits, licenses and  authorizations  necessary  for the  installation and operation of the Generator and the Tank. In addition to, and without limiting Tenant's obligations under the Lease, Tenant shall comply with all applicable environmental and fire prevention Laws  pertaining to  Tenant's use  of the  Generator  Area.   Tenant  shall  also be responsible for the cost of all utilities consumed in the operation of the Generator and the Tank.

		
	11.2
	Tenant shall be responsible for assuring that the installation, maintenance, operation and removal of the Generator and the Tank shall in no way damage any portion  of the  Building D. To the maximum extent 

permitted by Laws, the Generator and the Tank and all appurtenances in the Generator Area shall be at the sole risk of Tenant, and Landlord shall have no liability to Tenant if the Generator, the Tank or any appurtenances installations are damaged for any reason. Tenant agrees to be responsible for any damage caused to the Building D in connection with the installation, maintenance, operation or removal of the Generator. In addition, in accordance with the terms of Article 14 of the Original Lease, except to the extent caused by Landlord's gross negligence or willful misconduct, Tenant shall indemnify, defend and hold Landlord and the Landlord Patties harmless from all liabilities, obligations, damages, penalties, claims, costs, charges and expenses, including, without limitation, reasonable architects' and attorneys' fees (if and to the extent permitted by Laws), which may be imposed upon, incurred by, or asse1ted against Landlord or any of the Landlord Patties in connection with the installation, maintenance, operation or removal of the Generator and the Tan1c, including, without limitation, any environmental and hazardous materials claims. In addition to, and without limiting Tenant's obligations under the Lease, Tenant covenants and agrees that the installation and use of the Generator and  the Tank and appurtenances shall not adversely affect the insurance coverage for the Building D. If for any reason, the installation or use of the Generator, the Tan1c and/or the appurtenances shall result in an increase in the amount of the premiums for such coverage, then Tenant shall be liable for the full amount of any such increase.

		
	11.3
	Tenant shall be responsible for the installation, operation, cleanliness, maintenance and removal of the Generator and the Tan1c and the appurtenances, all of which shall remain the personal property of Tenant, and shall be removed by Tenant at its own expense at the expiration or earlier termination of the Lease. Tenant shall repair any damage caused by such removal, including the patching of any holes to match, as closely as possible, the color surrounding the area where the Generator, Tan1c and appurtenances were attached. Such maintenance and operation shall be performed in a manner to avoid any unreasonable interference with any other tenants or Landlord.  Tenant shall take the Generator Area "as  is" in the condition in which the Generator Area is in as of the Building D Delivery Date, without any obligation on the part of Landlord to prepare or construct the Generator Area for Tenant's use or occupancy. Without limiting the foregoing, Landlord makes no warranties or representations to Tenant as to the suitability of the Generator Area for the installation and operation of the Generator or the Tan1c. Tenant shall have no right to make any chat1ges, alterations, additions, decorations or other improvements to the Generator  Area without Landlord's prior written consent, which consent shall not be unreasonably withheld. Tenant agrees to maintain the Generator and the Tank, including without limitation, any enclosure installed around the Generator and the Tank in good condition and repair. Tenant shall be responsible for performing any maintenance and improvements to any enclosure surrounding the Generator and the Tank so as to keep such enclosure in good condition.

		
	11.4
	Tenant, upon prior notice to Landlord and subject to the rules and regulations enacted by Landlord, shall have access to the Generator and the Tan1c and its surrounding area for the purpose of installing, repairing, maintaining and removing the Generator and the Tan1c

		
	11.5
	Tenant shall be permitted to use the Generator Area solely for the maintenance and operation of the Generator and the Tank, and the Generator, Tan1c and Generator Area are solely for the benefit of Tenant. All electricity generated by the Generator may only be consumed by Tenant in the Building D Expansion Space. Landlord shall have  no  obligation to provide any services, including, without limitation, electric current, to the Generator Area.

		
	11.6
	Tenant shall have no right to sublet the Generator Area or except with respect to an assignee following a Permitted Transfer.

		
	11.7
	Notwithstanding anything to the contrary contained herein, if at any time during the Building D Term Landlord determines in its reasonable business judgment following reasonable investigation, that the Generator, Tan1c and/or any appurtenances cause or may reasonably cause a dangerous condition at the Project, then Tenant shall, upon notice from Landlord, cease any further operation of the Generator and Tan1c until Tenant demonstrates to Landlord's reasonable satisfaction that such dangerous condition has been  rectified.

		
	11.8
	During the Building D Term (as the same may be extended), Tenant shall not be obligated  to pay Landlord any Additional Rent or fee for the use of the Generator Area.

		
	12.
	Assignment and Subletting. The terms and conditions of Article  12 (Assignment and Subletting)  of the Original Lease shall apply to the Building D Expansion Space, provided, however, if (i) Tenant assigns the Lease, as amended 

hereby, Landlord shall have  the  right  to  terminate  the Lease, as amended hereby, with respect  to the  entirety  of the Premises,  or (ii) Tenant  subleases  all or substantially all of the Building D Expansion Space, Landlord shall have the  right  to terminate the Lease, as amended hereby, with respect to all or the p01iion of the Building D Expansion Space that Tenant is proposing to sublet. Moreover,  Section  12(B) of the  Original  Lease shall be modified by deleting clause (3) and substituting the  following therefor:  "(3) if  Tenant is assigning this Lease or is subleasing the entirety of fifty percent (50%) or more of the Premises located in one of the Buildings then  constituting  the  Premises  for  a term  exceeding more than half of the then remaining Term of the Lease with respect to the subject Building(s), exercise its right to terminate the Lease with respect to the portion of the Premises that Tenant is proposing to  assign or sublet."

		
	13.
	Roof Space For Dish/Antenna.

		
	13.1
	During the initial Building D Term and any extension thereof, Tenant shall have the right to lease space on the roof of Building D for the purpose of installing (in accordance with A1iicle 9 of the Original Lease), operating and maintaining a dish/antenna or other communication device (the "Dish/Antenna") to be approved by Landlord, such approval not to be unreasonably withheld, conditioned or delayed. The location of the space on the roof designated by Landlord to be leased by Tenant is referred to herein as the "Roof Space". Landlord reserves the right to relocate the Roof Space as reasonably necessary during Building D Term at Landlord's sole cost and expense (except to the extent such relocation is required due to Tenant's use or occupancy of the Premises). Landlord's designation shall take into account Tenant's use of the Dish/Antenna. Notwithstanding the foregoing, Tenant's right to install the Dish/Antenna shall be subject to the approval rights  of  Landlord   and  Landlord's  architect  and/or  engineer  with  respect  to  the  plans and specifications of the Dish/Antenna, the size of the Dish/Antenna, the manner in which the Dish/Antenna is attached to the roof of Building D and the manner in which any cables are run to and from the Dish/Antenna. The precise specifications and a general description of  the Dish/Antenna, or any replacements thereof, along with all documents Landlord reasonably requires to review the installation of the Dish/Antenna (the "Plans and Specifications") shall be submitted to Landlord for Landlord's written approval, such approval not to be unreasonably withheld, no later than twenty (20) days before Tenant c01mnences to install the Dish/Antenna. Tenant shall be  solely responsible  for obtaining and maintaining all necessary governmental and regulatory approvals and for the cost of installing, operating, maintaining and removing the Dish/Antenna. Tenant shall notify Landlord upon completion of the installation of the Dish/Antenna. If Landlord determines that the Dish/Antenna equipment does not comply with the approved Plans and Specifications, that Building D has been damaged during installation  of the Dish/Antenna  or that the installation was defective, Landlord shall notify Tenant of any noncompliance or detected problems and Tenant immediately shall cure the defects. If the Tenant fails to immediately cure the defects, Tenant shall pay to Landlord upon demand the cost, as reasonably determined by Landlord, of correcting any defects and repairing any damage to Building D caused by such installation. If at any time Landlord, in  its  reasonable  discretion, deems it necessary, Tenant shall provide and install, at Tenant's sole cost and expense, appropriate aesthetic screening, reasonably satisfacto1y to Landlord, for the Dish/Antenna (the "Aesthetic Screening").

		
	13.2
	Landlord agrees that Tenant, upon reasonable prior written notice to Landlord, shall have access to the roof of Building D and the Roof Space for the purpose of installing, maintaining, repairing and removing the Dish/Antenna, the appurtenances and the Aesthetic Screening, if any, all of which shall be performed by Tenant or Tenant's authorized representative or contractors, which shall be approved by Landlord, such approval not to be unreasonably withheld, at Tenant's sole cost and risk. It is agreed, however, that only authorized engineers, employees or properly authorized contractors of Tenant, FCC (defined below) inspectors, or persons under their direct supervision will be permitted to have access to the roof of Building D and the Roof Space. Tenant further  agrees to exercise firm control over the people requiring  access to the roof  of Building D and the Roof Space in order to keep to a minimum the number of people having access to the roof of Building D and the Roof Space and the frequency of their visits. It is further understood and agreed that the installation, maintenance, operation and removal of the Dish/Antenna, the appurtenances and the Aesthetic Screening, if any, is not permitted to damage Building D or the roof thereof, or interfere with the use of Building D and roof by Landlord. Tenant agrees to be responsible for any damage caused to the roof or any other part of Building D, which may be caused by Tenant or any Tenant Party.

		
	13.3
	Tenant agrees to install and maintain only equipment of types  and frequencies which will not cause unreasonable interference to Landlord or any other tenant of Building D. In the event Tenant's equipment causes such interference, Tenant will change the frequency on which it transmits and/or receives and take 

any other steps necessary to eliminate the interference.  If said interference cannot be eliminated within a reasonable period of time,   in the reasonable judgment of Landlord, then Tenant agrees to remove the Dish/Antenna from the Roof Space. Landlord shall make c01mnercially reasonable efforts to ensure that any new equipment installed on the roofs by other tenants or users does not  have frequencies  which  causes  unreasonable  interference  to  Tenant's  Dish/Antenna.  Tenant shall, at its sole cost and expense, and at its sole risk, install, operate and maintain the Dish/Antenna in a good and workmanlike manner, and in compliance with all Building D, electric, communication, and safety codes, ordinances, standards, Laws and requirements, now in effect or hereafter promulgated, of the Federal Government, including, without limitation, the Federal Communications Commission (the "FCC"), the Federal Aviation Administration ("FAA") or any successor agency of either the FCC or FAA having jurisdiction over radio or telecommunications, and of the state, city and county in which Building D is located. Landlord and its agents assume no responsibility for the licensing, operation and/or maintenance of Tenant's equipment. Tenant has the responsibility of carrying out the terms of its FCC license in all respects. The Dish/Antenna shall be connected to Landlord's power supply in strict compliance with all applicable Building D, electrical, fire and safety codes. Neither Landlord nor any Landlord Party shall be liable to Tenant for any stoppages or shortages of electrical power furnished to the Dish/Antenna or the Roof Space because of any act, omission or requirement of the public utility serving Building D, or the act or omission of any other tenant, invitee or licensee or their respective agents, employees or contractors, or for any other cause beyond the reasonable control of Landlord, and Tenant shall not be entitled to any rental abatement for any such stoppage or shortage of electrical power. Except to the extent caused by Landlord's gross negligence or willful misconduct, neither Landlord nor any Landlord Party  shall have any responsibility  or liability for the conduct or safety of any of Tenant's representatives, repair, maintenance and engineering personnel while in or on any part of Building D or the Roof Space.

		
	13.4
	The Dish/Antenna, the appurtenances and the Aesthetic Screening, if any, shall remain the personal property of Tenant, and shall be removed by Tenant at its own expense at the expiration or earlier termination of the Lease or Tenant's right to possession hereunder. Tenant shall repair any damage caused by such removal, including the patching of any  holes to match, as closely as possible, the color surrounding the area where the equipment and appurtenances were attached. Tenant agrees to maintain all of the Tenant's equipment placed on or about the roof or in any other part of Building D in proper operating condition and maintain same in satisfactory condition as to appearance and safety in La11dlord's reasonable discretion. Such maintenance and operation shall be performed in a mam1er to avoid any interference with any other tenants or Landlord. Tenant agrees that at all times during Building D Term, it will keep the roof of Building D and the Roof Space free of all trash or waste materials produced by Tenant or the Tenant Entities.

		
	13.5
	In light of the specialized nature of the Dish/Antenna, Tenant shall be permitted  to utilize the services of its choice for installation, operation, removal and repair  of  the Dish/Antenna, the appurtenances and the Aesthetic Screening, if any, subject to the reasonable approval of Landlord. Notwithstanding the foregoing, Tenant must provide Landlord with prior written notice of any such installation, removal or repair and  coordinate such work with Landlord in order to avoid voiding or otherwise adversely affecting any warranties granted to Landlord with respect to the roof.  If necessary, Tenant,  at its sole cost and expense, shall retain any contractor having a then existing warranty in effect on the roof to perform such work (to the extent that it involves the roof), or, at Tenant's option, to perform such work in conjunction with Tenant's contractor. In the event the Landlord contemplates roof repairs that could affect Tenant's Dish/Antenna, or which may result in an interruption of the Tenant's telecommunication service, Landlord shall formally notify Tenant in writing at least thirty (30) days in advance (except in cases of an emergency) prior to the commencement of such contemplated work in order  to  allow Tenant to make other arrangements for such service.

		
	13.6
	Tenant shall not allow any provider of telecommunication, video, data or related services ("Communication Services") to locate any equipment on the roof of Building D or in the Roof Space for any purpose whatsoever, nor may Tenant use the Roof Space and/or Dish/Antenna to provide Communication Services to an unaffiliated tenant, occupant or licensee of another Building D, or to facilitate the provision of Communication Services on behalf of another Co1mnunication Services provider to an unaffiliated tenant, occupant or licensee of Building D or any other Building D. Tenant specifically  acknowledges  and agrees that the terms and conditions of Article 14 of the Original Lease shall apply with full force and effect to the Roof Space and any other portions of the roof accessed or utilized by Tenant, its representatives, agents, employees or  contractors.

		
	13.7
	If Tenant defaults under any of the terms and conditions of this Section or the Lease, and Tenant fails to cure said default within the time allowed  by  Article  19 of the  Original Lease, Landlord shall be permitted to exercise all remedies provided under the terms of the Lease, as amended hereby, including removing the Dish/

Antenna,  the  appurtenances  and the Aesthetic Screening, if any, and restoring Building D and the Roof Space to  the condition that existed prior to the installation of the Dish/Antenna, the  appurtenances  and the Aesthetic Screening, if any. If Landlord removes the Dish/Antenna, the appurtenances and the Aesthetic Screening, if any, as a result of an uncured default, Tenant shall be liable for all costs and expenses Landlord incurs in removing the Dish/Antenna, the appurtenances and the Aesthetic Screening, if any, and repairing any damage to Building D, the roof of Building D and the Roof Space caused by the installation, operation or maintenance of the Dish/Antenna, the appurtenances, and the Aesthetic Screening, if any. Tenant's rights pursuant to this Section 13 are personal to the named Tenant and any assignee following a Permitted Transfer and assignees or subtenants consented to by Landlord pursuant to Article  12 of the Original Lease, and are not otherwise transferable.

		
	14.
	Renewal Options. Section 34 of the Original Lease is hereby deleted and shall be of no further force or effect

		
	14.1
	The Campus Renewal Option. Provided that (a) the Lease, as amended hereby, is in full force and effect, (b) Tenant is not and has not in the immediately preceding twelve (12) month period been in default under any of the other terms and conditions of the Lease, as amended hereby, beyond any applicable notice and cure periods  at the time of notification  or commencement, and (c) subject to the terms and conditions of this Amendment, then Tenant shall have one (1) option to extend the term of the Lease, as amended hereby (the "Campus Renewal Option") for a term of five (5) years (the "Campus Renewal Term"), for (x) the entirety of The Campus, or (y) the entirety of the square footage of Buildings E and F of the Project (for a total square footage of approximately  82,657 rentable  square  feet, as of the date of this Amendment), on the same terms and conditions set f01ih in the Lease, as amended hereby, except as modified by the terms, covenants and conditions as set forth below:

		
	14.1.1
	If Tenant elects to exercise the Campus Renewal Option, then Tenant shall provide Landlord  with written  notice  no  earlier than the  date which  is four hundred  fifty (450)  days  prior  to  the  expiration  of  the  Original  Premises  Extended  Term, as amended hereby, but no later than the date which is three hundred and sixty five (365) days prior to the expiration of the Original Premises Extended Term. If Tenant fails to provide such notice, Tenant shall have no further or additional right to extend or renew the term of the Lease.

		
	14.1.2
	The Base Rent in effect at the expiration of the Original Premises Extended Term shall be adjusted to reflect the Prevailing Market (defined below) rate. Landlord shall advise Tenant of the new Base Rent for Building E and F or the Campus, as the case may be, no later than thirty (30) days after Landlord's receipt of Tenant's exercise of its Campus Renewal Option under this Section 14.1. Said notification of the new Base Rent may include a provision for its adjustment to provide for a change in the Prevailing Market rate between the time of notification and the commencement of the Campus Renewal Term.

		
	14.1.3
	If Tenant and Landlord are unable to agree on a mutually acceptable Base Rent for the Campus Renewal Term not later than sixty (60) days prior to the expiration of the then-current Term, then Landlord and Tenant, within five (5) days after such date, shall each simultaneously submit to the other, in a sealed envelope, its good faith estimate of the Prevailing Market rate for the Building E and F or the Campus, as the case may be, during the Campus Renewal Term (collectively referred to as the "Estimates"). If the higher of such Estimates is not more than one hundred five percent (105%) of the lower of such Estimates, then the Prevailing Market rate shall be the average of the two Estimates. If the Prevailing Market rate is not established by the exchange of Estimates, then, within seven (7) days after the exchange of Estimates, Landlord and Tenant shall each select a commercial real estate appraiser to determine which of the two Estimates most closely reflects the Prevailing Market rate for the Premises during the Renewal Term. Each commercial real estate appraiser so selected shall be certified as an MAI appraiser or as an ASA appraiser and shall have had at least five (5) years experience within the previous ten (10) years as a real estate appraiser working in San Mateo, California, with working knowledge of current rental rates and practices. For purposes hereof, an "MAI" appraiser means an individual who holds an MAI designation conferred by, and is an independent member of, the American Institute of Real Estate Appraisers (or its successor organization, or in the event there is no successor organization, the organization and designation most similar), and an "ASA" appraiser means an individual who holds the Senior Member designation conferred by, and is an independent member of, the American Society of Appraisers (or its successor 

organization, or, in the event there is no successor organization, the organization and designation most similar).

		
	14.1.4
	Landlord's and Tenant's appraisers shall work together in good faith to agree upon which of the two Estimates most closely reflects the Prevailing Market rate for the Premises. The Estimate chosen by such appraisers shall be binding on both Landlord and Tenant. If either Landlord or Tenant fails to appoint an appraiser within the seven (7) day period referred to above, the appraiser appointed by the other party shall be the sole appraiser for the purposes hereof. If the two appraisers cannot agree upon which of the two Estimates most closely reflects the Prevailing Market rate within twenty (20)  days after their appointment, then, within ten (10) days after the expiration of such twenty  (20)  day period, the two appraisers shall select a third appraiser meeting the aforementioned criteria. Once the third appraiser (i.e., the arbitrator) has been selected as provided for above, then, as soon thereafter as practicable but in any case within fourteen (14) days, the arbitrator shall make his  or her  determination  of which of the two Estimates most closely  reflects  the Prevailing  Market  rate  and such Estimate shall be binding on  both  Landlord  and  Tenant  as  the Prevailing Market rate  for the  Campus,  or the entirety of Buildings  E and F, as  the case may be. If the arbitrator believes that expert  advice  would  materially assist him or her, he or she may retain one or more  qualified  persons to provide such expert advice. The patties shall share  equally in the  costs  of the  arbitrator and of any experts retained  by the arbitrator.  Any  fees of any  appraiser,  counsel or experts engaged directly by Landlord or Tenant,  however,  shall be borne  by  the party retaining  such appraiser,  counsel  or expert.

		
	14.1.5
	If the Campus Renewal Option is validly exercised or if Tenant fails to validly exercise the Campus Renewal Option, Tenant shall have no further right to extend the Original Premises Extended  Tenn.

		
	14.1.6
	For purposes of this Campus Renewal Option (and the Building D Renewal  Option), "Prevailing Market" shall mean the arms length fair  market  annual rental rate per rentable square foot under renewal leases and amendments entered into on or about the date on which the Prevailing Market is being determined hereunder for space comparable to the Premises and buildings comparable to the Buildings in the same rental market in the San Mateo and Foster City, California, area as of the date the Campus Renewal Term is to commence, taking into   account the specific provisions of the Lease, as amended hereby, which will remain constant, (B) any material economic differences between the te1ms of the Lease, as amended hereby, and any comparison lease or amendment, such  as  rent abatements, construction costs and other concessions and the manner, if any, in which the landlord under any such lease is reimbursed for operating expenses and taxes, and (C) tenant improvement allowances, free rent or other allowances or concessions typically offered to attract new tenants to the Project or comparable office buildings. The determination of Prevailing Market shall also take into consideration any reasonably anticipated changes in the Prevailing Market  rate from the time such Prevailing Market rate is being determined and the time such Prevailing Market rate will become effective under the Lease, as amended hereby.

		
	14.1.7
	If the Prevailing Market rent has not been determined by the commencement  date  of the Campus Renewal Term, Tenant shall pay monthly installments of rent upon the terms and conditions in effect during the last month of the Original Premises Extended Te1m until such time as the Prevailing Market rate has been determined. Upon such determination, the annual Rent and monthly installments of Rent for the Campus Premises shall be retroactively adjusted to the commencement of the Campus Renewal Term.

		
	14.2
	Building D Renewal Option. Provided that (a) the Lease, as amended hereby, is in full force  and  effect,  (b) Tenant  is not  and has not been  in the immediately  preceding twelve (12) month period  in default under  any of the  other terms and conditions  of the Lease, as amended hereby, beyond any applicable notice and cure periods  at the time of notification or c01mnencement, (c) subject to the terms and conditions of this Amendment, and (d) Tenant has exercised the Campus Renewal Option as set forth in Section 14.1 above or Tenant has otherwise extended the term of the Lease with respect to the entirety of The Campus for a term of five (5) or more years, then Tenant shall have  one  (1)  option to extend the term of the Lease, as amended hereby (the "Building D Renewal Option") for a term of five (5) years (the "Building D Renewal Term"), for the entirety of Building D, on the same terms and conditions set forth in the Lease, as amended hereby, except as  modified by the terms, covenants and conditions as set 

forth  below:

		
	14.2.1
	If Tenant elects to exercise the Building D Renewal Option, then Tenant shall provide Landlord with written notice no earlier than the date which is four hundred fifty (450) days prior to the expiration of the Building D Term, as amended hereby, but no later than the date which is three hundred and sixty five (365) days prior to the expiration of the Building D Term. If Tenant fails to provide such notice, Tenant shall have no further or additional right to extend or renew the term of the Lease.

		
	14.2.2
	The Base Rent in effect at the expiration of the Building D Term shall be adjusted  to reflect the Prevailing Market rate (as defined above in Section 14.1.6). Landlord shall advise Tenant of the new Base Rent for the Building D Expansion Space no later than thirty (30) days after Landlord's receipt of Tenant's written exercise of its Building D Renewal Option under this Section 14.2. Said notification of the new Base Rent may include a provision for its escalation to provide for a change in the Prevailing Market rate between the time of notification and the commencement of Building D Renewal Term.

		
	14.2.3
	If Tenant and Landlord are unable to agree on a mutually  acceptable  Base Rent  for  the  Building  D  Renewal  Term,  the  mechanism  set  forth  above  in Sections

14.1.3 and 14.1.4 to establish the Prevailing Rate for Buildings E and F or the Campus, as the case may be, shall apply to the parties' determination of the Prevailing  Rate for the Building D  Term.

		
	14.2.4
	If Building D Renewal Option is validly exercised or if Tenant fails to validly exercise Building D Renewal Option, Tenant shall have no further right to extend the Building D Renewal Term.

		
	14.2.5
	If the Prevailing Market rent has not been determined  by the commencement  date  of the Building D Renewal Term, Tenant shall pay monthly installments of rent upon the terms and conditions in effect during the last month of the Building D Term until such time as the Prevailing Market rate  has been  determined.  Upon such determination, the annual Rent and monthly installments of Rent for the Building D Expansion Space shall be retroactively adjusted to the commencement date of the Building D Renewal Te1m.

		
	14.3
	Conditions   Precedent.   In  the   event   Tenant   has   assigned   the  Lease  to a non­ Permitted Transferee, all of Tenant's renewal rights (that is, the Campus Renewal Option and the Building D Renewal Option, respectively) shall  arise  in  each  case only  so long as Tenant's tangible net w01th (as reasonably  evidenced to Landlord)  is equal to or greater than Tenant's tangible net worth on the date this Amendment is mutually executed and delivered both at the time of exercise  of  the  respective  renewal  option  and  at  commencement   of  the  respective  renewal  term.  Within ten (10) days of Landlord's written request, Tenant shall tender to Landlord Tenant's most recent (and in no event dated more than the prior calendar quarter) normal and customary financial statements prepared in accordance with generally accepted accounting principals and as reasonably requested by Landlord and audited and certified by a public accountant. In the event Tenant has sublet in the aggregate fifty percent (50%) or more of the portion of the Premises subject to the respective renewal option to a non-Permitted Transferee at the time of exercise of the subject renewal option and/or as of the commencement of the subject renewal term, such renewal option shall arise only so long as Tenant's tangible net worth (as reasonably evidenced to Landlord) is equal to or greater than Tenant's tangible net wo1ih as of the date this Amendment is mutually executed both at the time of exercise of the respective option and at commencement of the respective renewal term. In  all events Tenant shall remain liable for the obligations under the Lease during any renewal terms. Notwithstanding the foregoing, so long as Tenant is  a publicly traded company on an "over-the-counter" market or any recognized national or international securities exchange, the foregoing shall not apply so long as Tenant's current public annual report (in compliance with applicable securities laws) for such applicable year is available to Landlord in the public domain.

		
	15.
	Building C Expansion Option.

		
	15.1
	Grant of Option; Conditions. Tenant shall have the option (the "Building C Expansion Option") to lease the entirety of the building located at 3055 Clearview Way, San Mateo, California ("Building C"), containing approximately 68,025 rentable square feet of space (the "Building C Expansion Space") subject to the terms and conditions set fo1ih below in this Section 15. The Building C Expansion Space is currently leased by Landlord  to SolarCity Corporation, a Delaware corporation ("SolarCity"), pursuant to the terms of a lease 

dated July 30, 2010, as the same may be amended from time to time (the "Solar City Lease"). The SolarCity Lease is scheduled to expire on July 31, 2017.  Tenant  may exercise the Building C Expansion Option if:

		
	15.1.1
	SolarCity has not exercised its option to extend the term of the SolarCity Lease, which SolarCity option must be exercised no later than July 31, 2016;  and,

		
	15.1.2
	Landlord receives written notice (the "Building C Expansion Notice") from  Tenant of the exercise of its Building C Expansion Option on or before January 31, 2017 (i.e., the date that is six (6) months following the expiration of the period during which SolarCity can exercise its option to extend the term of the SolarCity Lease); and,

		
	15.1.3
	Tenant is not in default under the Lease, as amended hereby,  beyond  any  applicable cure periods at the time that Landlord receives the  Building  C Expansion Notice; and,

		
	15.1.4
	Other than in connection with a Permitted Transfer, the Lease, as amended hereby, has not been assigned and no more than 50% of the Premises (including The Campus and the Building D Expansion Space) is sublet (other than pursuant to a Permitted Transfer) at the time Landlord receives the Building C Expansion Notice; and,

		
	15.1.5
	The Building C Expansion Space is intended for the exclusive use of Tenant only during the Original Premises Extended Te1m; and

		
	15.1.6
	Tenant has not vacated or abandoned any portion of the Premises at the time Landlord receives the Building C Expansion Notice.

		
	15.2
	Terms for Building C Expansion Space.

		
	15.2.1
	The term for the Building C Expansion Space (the "Building C Term") would commence one hundred twenty (120) days from the execution and delivery of a lease amendment, or other written agreement, adding the Building C Expansion Space to the Premises and delivery of the Building C Expansion Space to Tenant (the "Building C Expansion Effective Date"), and shall end, unless sooner terminated pursuant to the terms of the Lease, on the Original Premises Extended Termination Date, it being the intention of the parties hereto that the term for the Building C Expansion Space and the Term for The Campus shall be coterminous. If Landlord is delayed delivering possession of the Building C Expansion Space due to the holdover or unlawful possession of such space by any party, Landlord shall use reasonable efforts to obtain possession of the space (provided however, that the foregoing shall not be deemed to require Landlord to institute legal proceedings), and the commencement of the term for the Building C Expansion Space shall be postponed until the date Landlord delivers possession of the Building C Expansion Space to Tenant free from occupancy by any party. Pursuant to the SolarCity Lease, SolarCity has the right to holdover in the Building C Expansion Space for up to three (3) months. If SolarCity elects to holdover, then Landlord shall provide prompt written notice of such holdover to Tenant.

		
	15.2.2
	The initial monthly Base Rent rate per rentable square foot for the Building C Expansion Space shall be Three and 30/100 Dollars ($3.30) per month, and shall increase annually by three percent (3%) on the anniversary of the Building C Expansion Effective Date. Base Rent attributable to the Building C Expansion Space shall be payable in monthly installments in accordance with the terms and conditions of the Lease, as amended hereby.

		
	15.2.3
	For the period commencing with the Building C Expansion Effective Date and ending on the Original Premises Extended Termination Date, Tenant shall pay all additional rent payable under the Lease, including Tenant's Share of Expenses and Taxes applicable to the Building C Expansion Space, in accordance with the terms of the Lease, as amended hereby.

		
	15.2.4
	The Building C Expansion Space (broom clean and free of any prior tenant's personal property, furniture, fixtures and equipment and all data cabling) shall be accepted by Tenant in its "as-built" condition and configuration existing on the earlier of the date Tenant takes possession of the Building C Expansion Space or as of the date the term for the Building C Expansion Space commences. In 

addition, Tenant shall be entitled to an improvement  allowance with respect to the Building  C Expansion Space in the amount of $15.00 per rentable square foot of  the  Building C Expansion Space (the "Building C Improvement Allowance"). In no event shall the Building C Improvement Allowance be used for the purchase of equipment, furniture or other items of personal property of Tenant. If Tenant does not submit a request for payment of the entire Building C Improvement Allowance to Landlord in accordance with the provisions contained in Exhibit C within the  first one hundred eighty (180) days of the Building C Expansion  Effective  Date, any unused amount shall accrue to the sole benefit of Landlord, it being understood that Tenant shall not be entitled to any credit, abatement or other concession in connection therewith. The Building C improvement  Allowance  shall  be  distributed to Tenant in the same manner as set forth in Exhibit C attached hereto with respect to disbursement of the Building D Allowance.

		
	15.2.5
	The Building C Expansion Space shall be considered a part of  the  Premises, subject to all the terms and conditions of the Lease, as amended hereby, except that no allowances, credits, abatements or other concessions (if any) set f01ih in the Lease for the remainder of the Premises shall apply to the Building C Expansion Space, except as may be specifically provided otherwise in this Building C Expansion Option provision.

		
	15.2.6
	If Tenant is entitled to and properly exercises the Building C Expansion Option, Landlord shall prepare an amendment (the "Building C Expansion Amendment") to reflect the commencement date of the term for the Building C Expansion Space and the changes in Base Rent, rentable square footage of the Premises, Tenant's Share and other appropriate terms. h1 addition, to the extent the same are not removed by or on behalf of SolarCity, Tenant shall have the right use the electric charging stations installed by SolarCity as well as the right to install four (4) enclosed bicycle storage lockers (provided that Tenant shall install the same as part of the Tenant Work and the terms and conditions of this Amendment, including without limitation, Exhibit C attached hereto, shall apply). A draft of the Building C Expansion Amendment shall be sent to Tenant within a reasonable time after Landlord's receipt of the Building C Expansion Notice,  and Tenant  shall execute (or provide comments and corrections) and return the Building C Expansion Amendment to Landlord within fifteen (15) business days thereafter (and shall thereafter work together with Landlord to timely finalize the Building C Expansion Amendment), but an otherwise valid exercise of the Building C Expansion Option shall be fully effective whether or not the Building C Expansion Amendment is executed.

		
	16.
	Right of First Offer.

		
	16.1
	Provided that Tenant has not timely and validly exercised the Building C Expansion Option set fo1ih above, Tenant shall have an ongoing right of first offer (the "Offer Right") with respect to the Building C Expansion Space. Tenant's Offer Right shall be exercised as follows:  at any time  after Landlord  has  determined  that the  Building  C Expansion Space has become Available (defined below), but prior to leasing the Building C Expansion Space to a party other than the existing tenant thereto, Landlord shall advise Tenant (the  "Advice") of the terms under which Landlord is prepared to lease the Building  C  Expansion Space to Tenant. For purposes hereof, the Building C Expansion Space shall be deemed to become "Available" as follows: if the Building  C Expansion  Space is under lease to a third patty as of the date of mutual  execution  and delivery  of this Amendment, the Building C Expansion Space shall be deemed to become Available when Landlord has determined that the third-party tenant of the Building C Expansion Space will not extend or renew the term of its lease, or enter into a new lease, for the Building C Expansion Space. Tenant may lease the Building C Expansion Space in its entirety only, under the terms set forth in the Advice, by delivering written notice of exercise to Landlord (the "Notice of Exercise") within :fifteen (15) business days after the date of the Advice, except that Tenant shall have no such Offer Right and Landlord need not provide Tenant with an Advice with respect to the Building C Expansion Space, if:

		
	16.1.1
	Tenant is in default under the Lease, as amended hereby, beyond any applicable notice and cure periods at the time that Landlord would otherwise deliver the Advice; or 

		
	16.1.2
	more than twenty five percent (25%) of the Premises is sublet at the time Landlord would otherwise deliver the Advice; or

		
	16.1.3
	other than in connection with a Permitted Transfer, the Lease, as amended hereby, has been assigned 

prior to the date Landlord would otherwise deliver the Advice;  or

		
	16.1.4
	Tenant or a Permitted Transferee is not occupying at least seventy five percent (75%) of the Premises on the date Landlord would otherwise deliver the Advice; or

		
	16.1.5
	the existing tenant in the Building C Expansion Space is interested in extending or renewing its lease for the Building C Expansion Space or entering into a new lease for the Building C Expansion Space.

		
	16.2
	The term for the Building C Expansion Space shall commence upon the commencement  date stated in the Advice and thereupon such Building C Expansion Space shall be considered a part of the Premises, provided that all of the terms stated in the Advice, including the termination date set forth in the Advice, shall govern Tenant's leasing of the Building C Expansion Space and only to the extent that they do not conflict with the  Advice, the terms and conditions of the Lease, as amended hereby, shall apply to the Building C Expansion Space. Tenant shall pay Base Rent, Tenant's Share of Expenses and Taxes and any other Additional Rent for the Building C Expansion Space in accordance with the terms and conditions of the Advice.

		
	16.3
	The Building C Expansion Space (including improvements and personalty, if any) shall be accepted by Tenant in its condition and as-built configuration existing on the earlier of the date Tenant takes possession of the Building C Expansion Space or the date the term for such Building C Expansion Space commences, unless the Advice specifies work to be performed  by  Landlord  in the Building  C Expansion  Space, in which case Landlord shall perform such work in the Building C Expansion Space. If Landlord is delayed delivering possession of the Building C Expansion Space due to the holdover  or unlawful  possession of such space by any party, Landlord shall use reasonable efforts to obtain possession of such space, and the commencement of the term for the Building C Expansion  Space shall  be postponed until the date Landlord delivers possession of the  Building  C Expansion Space to Tenant free from occupancy by any party.

		
	16.4
	The rights of Tenant hereunder with respect to the Building C Expansion Space shall terminate on the earlier to occur of: (i) Tenant's failure to exercise its Offer Right within the ten (10) business day period provided in Section 16.1 above; and (ii) the date Landlord would have provided Tenant the Advice if Tenant had not been in violation of one or more  of the conditions set f01ih in Section  16.1 above.

		
	16.5
	If Tenant exercises its Offer Right, Landlord shall prepare the Building C Expansion Space Amendment adding the Building C Expansion  Space to the Premises on the terms set fo1ih  in the Advice and reflecting the changes in the Base Rent, rentable square footage of the Premises, Tenant's Share and other appropriate terms. A draft of the Building C Expansion Space Amendment shall be sent to Tenant within a reasonable time after Landlord's receipt of the Notice of Exercise executed by Tenant, and Tenant shall execute and return the Building C Expansion Space Amendment to Landlord within fifteen (15)  days thereafter, but an otherwise valid exercise of the Offer Right shall be fully effective whether or not the Building C Expansion Space Amendment is  executed.

		
	17.
	Roof Top Deck. Tenant has requested Landlord's consent to install a Roof Top Deck (the "Roof  Top Deck Deck"). Landlord has not granted such consent. Tenant acknowledges and agrees that as of the date hereof, Tenant has been informed and understands that the installation of the Roof Top Deck on the roof of the Building D Expansion Space is not currently supp01ted by the Building's design structure and that the required approvals and permits to install a Roof Top Deck  at the Prope1iy are not currently feasible. Subject to Landlord's approval, which may be withheld in Landlord's sole discretion, Tenant may pursue efforts to obtain all governmental permits and approvals required for the installation of the Roof Top Deck or other roof top amenity (e.g., a communal gathering space) at the Property at its sole cost and expense and Tenant shall keep Landlord apprised in writing of the status of its effo1is in this  regard.  Tenant  shall  obtain  Landlord's prior written approval of any changes to be made to the structure of the Building D Expansion Space and Tenant shall pay for all design, engineering and construction plans that are required for the installation of the Roof Top Deck or other roof top amenity. The feasibility of such installation at the Building D Expansion Space shall be reasonably determined by  Landlord.  Tenant's construction and use of the Roof Top Deck or other roof top amenity shall at all times comply with all applicable Laws and shall not adversely affect other tenants or occupants of the Property, Landlord's use and/or the general operations of the Property. In addition to and wholly  apart from Tenant's obligation to pay Tenant's Share of Expenses and Taxes, Tenant shall be responsible for and shall pay prior to delinquency any taxes or governmental service  fees,  possessory interest taxes, fees or charges in lieu of any such taxes, capital levies, or other charges imposed upon, levied with respect to or assessed against its fixtures or personal property, on the  value of Roof Top Deck or other roof top amenity improvements within the  Property  or  

any increase in any of the foregoing based on such Roof Top Deck improvements or other roof top amenity. To the extent that any such taxes are not separately assessed or billed to Tenant, Tenant shall pay the amount thereof as invoiced to Tenant by Landlord. Tenant shall, at its sole cost and expense,  comply  with the terms  of the Lease,  as  amended  hereby,  and with  all  applicable Laws regarding the construction, operation, maintenance and removal of the Roof Top Deck or other roof top amenity installed by Tenant. In addition, Landlord has the right to require Tenant to obtain additional types and amounts of insurance in connection with the Roof Top Deck or other roof top amenity. Tenant shall be required to remove the Roof Top Deck at the expiration or earlier te11nination of the Term of the Lease, as amended hereby, and restore the  Property  to  the  condition existing prior to the installation, use and removal of the same. Tenant shall provide Landlord with permits and approvals required for the installation  of the Roof Top Deck or other  roof top amenity no later than twenty-four (24) months prior to the expiration of the Term of the Lease, as amended hereby, or otherwise forego the right to install such Roof Top Deck. Within a reasonable time after submission by Tenant to Landlord of copies of all permits and approvals required for the installation of the Roof Top Deck or other roof top amenity, Landlord shall present Tenant with an amendment to the Lease reflecting the construction schedule, approvals, and other pe1tinent matters, and otherwise evidencing Tenant's right to construct such the Roof Top Deck or other roof top amenity.

		
	18.
	Park. Subject to the te1ms specified above, Landlord shall contribute up to  $600,000.00  (the  "Park Allowance") for Tenant to use towards the design, planning and construction of an exclusive outdoor Park which could potentially include walking and bike trails within the location outlined on Exhibit E attached hereto and made a part hereof (the "Park"). The Park shall be exclusive to Tenant and, accordingly, Tenant shall construct fencing or other similar enclosure around the perimeter of the Park, which perimeter shall be subject to Landlord's prior written approval, which approval shall not be unreasonably withheld, and which shall further establish the  actual location and size of the Park. Tenant, not Landlord shall be liable to enforce the exclusivity of the Park and Tenant hereby waives and releases Landlord in connection with any liability therefor.

In the event Tenant elects to construct the Park, Tenant shall provide reasonable prior written notice of the same to Landlord and following the establishment of the location and size of the Park as described above, Landlord and Tenant shall enter into an amendment to the Lease to clearly depict the same and shall construct the Park in accordance with the terms and conditions of the Lease, as amended. Tenant will oversee the construction of the Park with Landlord's approval. The Park Allowance shall be distributed to Tenant in the same manner as set forth in Exhibit C attached  hereto with respect to disbursement of the Building D Allowance; provided, however, that if Tenant does not submit a request for payment of the entire Park Allowance to Landlord in accordance with the provisions contained in Exhibit C, on or before the expiration of sixty (60) months from the Building D Expansion Effective Date (the "Park Allowance Expiration Date"), any unused amount shall accrue to the sole benefit of Landlord, it being understood that Tenant shall not be entitled to any credit, abatement or other concession in connection therewith.

		
	18.1
	Tenant shall be responsible for obtaining all govermnental permits and approvals required for the installation of the Park at the Property at its sole cost and expense and Tenant shall keep Landlord apprised in writing of the status of its eff01ts in this regard. Subject to the application of the Park Allowance, Tenant shall pay for all design, engineering and construction plans and all construction costs, and any and all other costs and expenses, in connection with the installation of the Park. Tenant's construction and use of the Park shall  at all times comply with all applicable Laws and shall not adversely affect other tenants or occupants of the Prope1ty, Landlord's use and/or the general operations of the Property. In addition, Landlord has the right to reasonably require Tenant to obtain additional types and amounts of insurance in connection with the Park.

		
	18.2
	Tenant shall have the exclusive use of the Park for Tenant, its employees and invited guests and shall require each user of the Park to execute a release and waiver specifically stating that Landlord shall not directly or indirectly be liable to any user of the Park and that such user waives any and all claims against and releases Landlord and its trustees, members, principals, beneficiaries, partners, officers, directors, employees,  any  mortgagees  and agents from any and all claims (whether known or unknown) arising as a consequence of or related to the Park. Tenant shall be solely liable for the operation, management, repair and maintenance of the Park.

		
	18.3
	All Park improvements shall remain the property of Tenant until the expiration or earlier termination of the Lease, as amended hereby, at which time the Park improvements, other than furniture, fixtures and equipment, shall be and become the property of Landlord; provided, however, that Landlord may, at Landlord's option, require that Tenant,  at  Tenant's expense, remove any or all Park improvements (other than normal and customary walking and building trails) made by Tenant and restore the portion of the Property upon which the Park is located by the expiration or earlier termination of the Lease. All such removals and restoration shall be accomplished in a first-class and good and workmanlike manner so as not to cause any damage to the Property  whatsoever.  If Tenant  fails to remove such Park improvements or other personal prope1iy so required by Landlord, Landlord may keep and use them or remove any of them and cause them to be  stored or  sold in accordance with applicable Laws, at Tenant's sole  expense.

		
	18.4
	In addition to and wholly apart from Tenant's obligation to pay Tenant's Share of Expenses and Taxes, Tenant shall be responsible for and shall pay prior to delinquency any taxes or governmental service fees, possessory interest taxes, fees or charges in lieu of any such taxes, capital levies, or other charges imposed upon, levied with respect to or assessed against its fixtures or personal prope1iy, on the value of Park improvements within the Property or any increase in any of the foregoing based on such Park improvements. To the extent that any such taxes are not separately assessed or billed to Tenant, Tenant shall pay the amount thereof as invoiced to Tenant by Landlord. Tenant shall, at its sole cost and expense, comply with the terms of the Lease, as amended hereby, and with all applicable Laws regarding the construction, operation, maintenance and removal of the Park.

		
	18.5
	In the event that, following Tenant's good faith, reasonable efforts to obtain any required approval from the local jurisdiction for the development of the Park as described in this Section 18, so long as Tenant notifies Landlord in writing of the same, which written notice shall include reasonable documented evidence of Tenant's good faith, reasonable effo1is to obtain such approval (together with the formal written rejection or other document  reflecting the withholding of consent for such approval), Tenant may, at its election but otherwise subject to the terms and conditions of this Amendment, including, without limitation, the effectiveness of the Park Allowance Expiration Date, apply the Park Allowance to Tenant's construction of an outdoor amenity at the Property (the "Future Outdoor Amenity"). Tenant's right to construct any such Future Outdoor Amenity  is subject to Landlord's prior written consent (which consent shall not be unreasonably withheld), including with respect to location, sign, type of amenity, exclusive or nonexclusive nature of the same. In any event, Tenant shall be required to construct, repair and maintain, and, if required by Landlord, at the end of the applicable Term, remove all or any part of such Future Outdoor Amenity, all at Tenant's sole cost and expense. If Tenant elects to construct the Future Outdoor Amenity pursuant to this  Section  18.5, and if   at the time Tenant tenders to Landlord final construction documents for the Future Outdoor Amenity for Landlord's prior written approval, and together with such final construction documents requests that Landlord notify Tenant whether Tenant shall be required to  remove all or any part of such Future Outdoor Amenity, then Landlord shall, at the time it consents to such final construction documents, notify Tenant in writing which portions, if any of the Future Outdoor Amenity Tenant shall be required to remove and restore at the expiration or earlier termination of the Lease. In the event Tenant elects to construct the Future Outdoor Amenity in accordance with this Section 18.5 and Landlord approves the same pursuant to the terms hereof, Landlord and Tenant shall enter into an amendment to the Lease providing for such construction, including, without limitation, the appropriate  and reasonable terms and conditions applicable thereto. In any event, Tenant, not Landlord, shall be liable at its sole cost and expense for the repair, maintenance, operation and replacement of such Future Outdoor Amenity, including without limitation, the removal of all or part of the same if requested by Landlord.

		
	19.
	Intentionally Omitted

		
	20.
	Other Pertinent Provisions. Landlord and Tenant agree that, effective as of the date of this Amendment (unless different effective date(s) is/are specifically referenced in this Section), the Lease shall be amended in the following additional respects:

		
	20.1 
	Insurance.  Tenant's insurance required under Article 15 of the Original Lease ("Tenant's Insurance")  shall include  the Building  D Expansion  Space.   No  less than ten (10) days prior to the Building D Expansion Effective Date, Tenant shall provide Landlord with a ce1iificate of insurance, in form  and  substance  satisfact01y  to Landlord and otherwise in compliance with A1iicle 15 of the  Original  Lease,  evidencing  that Tenant's  Insurance covers  the   Original   Premises   and  Building  D  Expansion   Space. In addition to the requirements set fo1ih in the Original Lease, all insurance carried by Tenant pursuant to the terms and conditions of the Lease, as amended, shall name as additional insureds Landlord, Landlord's investment managers, mortgagees, property managers  and  any  other  party reasonably  requested by Landlord.

		
	20.2
	Subordination. Landlord hereby represents and warrants that as of the date of this Amendment there is no mortgage or deed of trust encumbering Landlord's title to the Premises.

		
	20.3
	Parking. Effective as of the Building D Expansion Effective Date, Tenant shall be entitled to additional unreserved parking spaces at a ratio of 3.5 spaces per 1,000 rentable square  feet of the Building D Expansion Space, which as of the date of this Amendment, is a total of 388 unreserved parking spaces. Furthermore, Section 2 of Exhibit F to the  Original  Lease (Parking Agreement), is hereby amended to reflect that, as of the date hereof, the ratio of parking spaces for The Campus shall also be 3.5 spaces per 1,000 rentable square feet of rentable square feet. Accordingly, Tenant shall be entitled to unreserved parldng spaces at a ratio of 3.5 spaces per 1,000 rentable square feet of The Campus, which as of  the date of this Amendment, is a total of 698 unreserved parking spaces. In the aggregate, Tenant shall be entitled to 1086 unreserved parking spaces at the parking facility for the Project. Except as modified herein, the use of such unreserved parking spaces shall be subject to the terms of the Lease.

		
	20.4
	Parking Garage. Additionally, so long as Tenant continues to lease the entirety of The Campus (for an aggregate of 199,458 rentable square feet, as of the date hereof) and Building D (for an aggregate of 110,876 rentable square feet, as of the date hereof),   Tenant

(i) shall have the exclusive right to all parking spaces in the parking garage of the Project (the "Garage") which, as of the date of this Amendment, has capacity for 817 unreserved parking spaces, (ii) shall have an additional 269 unreserved parking spaces in the surface parking lot of the Project, (iii) Tenant shall have the right to install  Tenant's  security  system and otherwise secure the Garage, and (iv) shall have the right to install its business name and/or corporate logo on the Garage (subject to the same terms and conditions with respect to Building D Signage as set forth in Section 10.1 above). All parking shall be free  of charge during the remainder of the Term and the later to expire of the Building D Term and during any renewal of the term of the Lease, as amended hereby, pursuant  to  the options set fo1ih in this Amendment. Notwithstanding the foregoing, in the event  that  Tenant assigns the Lease (other than as part of a Permitted Transfer) or does not renew the Lease with respect to any of the wholly-leased buildings that Tenant currently leases hereunder, then (a) Tenant shall no longer have exclusive rights to the Garage and shall remove its security system and branding insignia promptly from the Garage and repair the Garage to the condition in which it was prior to such installations, and (b) Tenant shall  retain the unreserved parking spaces at a ratio of 3.5 spaces per  1,000 rentable square feet  of space during the remainder of the Term.  Only to the extent Tenant's rights with respect  to the Garage as set forth in this Section 20.4 are in full force and effect, Tenant may sublease the right to use Tenant's parking as set f01ih herein to subtenants under subleases entered into in accordance with the terms and conditions of the Lease, as amended, on a propo1iionate basis the subject sublet premises bears to the total Premises (including The Campus and the Building D Expansion Space).

		
	20.5
	Hazardous Materials. Tenant shall not be liable for any cost or expense  related  to removal, cleaning, abatement or remediation of Hazardous Materials existing in  the Building D Expansion Space prior to the date Landlord tenders possession of the Building  D Expansion Space to Tenant, including, without limitation, Hazardous Materials in the ground water or soil, except to the extent that any of the foregoing results directly or indirectly from any act or omission by Tenant or any Tenant Entity or any Hazardous Materials disturbed, distributed or exacerbated by Tenant or any Tenant Entity.

		
	21
	Lease Modifications.    From  and  after  the  date  of  this  Amendment,  unless  otherwise set f01ih herein, the following shall apply:

		
	21.1
	Use. Section l(J) of the Lease is hereby modified by adding the phrase "media production" to the Permitted Use in the Lease. For purposes hereof "media production" shall mean the conception, creation and development of audio, video, and other digital media, and includes, but is not limited to, the filming, photographing, recording, enhancement, encoding, and distribution of digital files using numerous methods of processing via hardware  and software applications.

		
	21.2
	Grade Level Door. From and after the date of this Amendment, Tenant shall exclusive  rights to use in accordance with the terms and conditions of the Lease,  as amended,  at  least one (1) grade level door (selected  by Landlord)  at Building   F.

		
	21.3
	Service Interruption. The following language is hereby added to the end of Section 7(C) of the Original Lease:

"Notwithstanding the foregoing, in the event of any Services Failure of services or utilities to be provided by Landlord hereunder which failure caused by or arising from Landlord's gross negligence or willful misconduct, and if Tenant tenders to Landlord written notice ("Abatement Notice") of any such Service Failure, and if such Service Failure continues beyond the "Eligibility Period" (as that term is defined below), then Base Rent and Tenant's Share of Expenses and Taxes shall be abated entirely or reduced, as the case may be, after expiration of the Eligibility Period for such time that Tenant continues to be so prevented from using, and does not use, the Premises, or a portion thereof, in the proportion that the leasable square feet of the portion of the Premises that Tenant is prevented from using, and does not use, bears to the total leasable square feet of the Premises. Notwithstanding anything to the contrary contained herein, if Landlord is diligently pursuing the restoration of such services or utilities and Landlord provides substitute services or utilities reasonably suitable for Tenant's purposes as reasonably determined by Landlord, for example bringing in portable air conditioning or heating equipment, then there shall be no abatement of Base Rent and Tenant's Share of Expenses and Taxes. The term "Eligibility Period" shall mean a period of ten (10) consecutive business days after Landlord's receipt of the applicable Abatement Notice. Such right to abate Base Rent and Tenant's Share of Expenses and Taxes shall be Tenant's sole remedy for an Abatement Event. This Section shall not apply in case of damage to, or destruction of, the Premises or the Project, or any eminent domain proceedings which shall be governed by separate provisions of the Lease."

		
	21.4
	Alterations. In Section 9(C) of the Original Lease, the reference to "$50,000 in the aggregate" shall be modified to provide as follows, "$50,000 per each of the Buildings which then constitutes the Premises in the aggregate".

		
	21.5
	Monetary Default. Section 19(A) of the Original Lease is hereby deleted and the following language is hereby substituted therefor: "Tenant's failure to pay when due all or any portion of the Rent within five (5) days after the date on which Landlord provides written notice that such amount is past due; provided, however, Landlord shall not be obligated to provide written notice of monetary default more than two (2) times in any calendar year, and each subsequent monetary default shall be an Event of Default if not received within five (5) days after the same is due; provided further, such notice shall be in lieu of, and not in addition to, any notice required under Section 1161 et seq. of the California Code of Civil 

Procedure  ("Monetary Default")."

		
	21.6
	Event of Default. Section 19(E) of the Original Lease is hereby deleted in its entirety and shall be of no further force or effect.

		
	21.7
	Financial Statements. Notwithstanding the foregoing, so long as Tenant is a publicly traded company on an "over-the-counter" market or any recognized national or international securities exchange, the foregoing shall not apply so long as Tenant's current public annual report (in compliance with applicable securities laws) for such applicable year is available to Landlord in the public domain.

		
	21.8
	Holding Over. A1iicle 25 of the Original Lease shall be amended as follows:  after the  words "during the holdover) equal to" insert the following: "(i) 125% of the sum of the  Base Rent and Additional Rent due for  the  period  immediately  preceding  the holdover for the first thirty (30) days of any such holding over period, and, (ii) from and after the thirty-first (31st) day of any such holding over  period".

		
	21.9
	Insurance.   Article  15 of the Original Lease is hereby  amended  as follows:

		
	21.9.1
	The last sentence of Section 15.D is hereby deleted, provided, however, that Landlord and Tenant acknowledge and agree that premiums and deductibles for earthquake insurance coverages obtained by Landlord shall be included in Expenses, subject to the express limitations set f01ih in Exhibit E to the Original Lease.

		
	21.9.2
	Section  15.G.3 is hereby  deleted  and replaced with the following:  "shall contain  a provision whereby each insurer agrees to give Landlord at least  ten  (10)  business days prior written notice of cancellation due to failure to pay premiums; provided, however, that Tenant shall provide no less than ten (10) business days prior written notice of any cancellation for any other reason or adverse change of any of Tenant insurance coverages as required by this Lease (as the same may be amended);".

		
	21.10
	Exhibit  E  (Expenses  and  Taxes).    The  following  modifications  are  hereby  modified as follows:

		
	21.10.1
	The following language is hereby added to the end of Paragraph B: "Notwithstanding anything set forth  in the Lease,  the  following  items  shall not be included in Expenses: (A) The cost of correcting defects in the original construction of the Building, (B) the cost of any work  or service performed  for  any tenant of the Project (other than Tenant) to a materially greater extent or in a materially more favorable manner than that  furnished  generally  to  the  tenants and other occupants (including Tenant), (C) any costs included in Expenses representing an amount paid to a corporation related to Landlord which  is  in excess of the amount which would have been paid in the absence of such relationship, (D) salaries, wages, or other compensation or benefits paid to employees of Landlord who are not assigned full-time to the operation, management, maintenance, or repair of the Project; provided however, Expenses shall include Landlord's reasonable allocation of wages, salary, or other compensation or benefits paid to any employee to the extent such employee is assigned or devotes services on a part-time basis to the operation, management, maintenance, or repair of the Project, (E) with respect to Expenses arising in connection with Building D only, costs incurred by Landlord to comply with the ADA or any other governmental requirements (to the  extent  the  same  are  in effect and as interpreted  and enforced on the date of this   Amendment).

		
	21.10.2
	Paragraph B, Section 4 shall be modified as follows: With respect to earthquake insurance only, the reference to "$100,000.00" shall be amended to be "$250,000.00."

		
	21.10.3
	Paragraph D shall be revised by deleting  "90  days"  and  substituting  "one  hundred and eighty (180) days" therefor. In the 11th to last line of this paragraph, the phrase "90 day" shall be deleted and  the  phrase  "180  day"  shall  be substituted therefor.

		
	22
	Miscellaneous.

		
	22.1
	This Amendment, including Exhibit A (Outline and Location of Building D Expansion Space), Exhibit B (Landlord Work), Exhibit B-1 (Current Permit Drawing List), Exhibit  C (Tenant Work), and Exhibit D (Location of Potential Exterior Perimeter of  Park)  attached hereto, sets forth the entire agreement between the parties with respect to the matters set forth herein. There have been no additional oral or written representations or agreements. Under no circumstances shall Tenant be entitled to any Rent abatement, improvement allowance, leasehold improvements, or other work to the Premises, or any similar economic incentives that may have been provided Tenant in connection with entering into the Lease, unless specifically set forth in this Amendment.

		
	22.2
	Except as herein modified or amended, the provisions, conditions and terms of the Lease shall remain unchanged and in full force and effect. In the case of any  inconsistency between the provisions of the Lease and this Amendment, the provisions of this  Amendment shall govern and control. The capitalized terms used in this Amendment shall have the same definitions as set forth in the Lease to the extent that such capitalized terms are defined therein and not redefined in this Amendment.

		
	22.3
	Submission of this Amendment by Landlord is not an offer to enter into this Amendment but rather is a solicitation for such an offer by Tenant. Landlord shall not be bound by this Amendment until Landlord has executed and delivered the same to Tenant.

		
	22.4
	Tenant hereby represents to Landlord that Tenant has dealt with no broker in connection with this Amendment, other than Jones, Lang, LaSalle. Tenant agrees  to indemnify  and hold Landlord and the Landlord Parties harmless from all claims of any other brokers claiming to have represented Tenant in connection with this Amendment. Landlord hereby represents to Tenant that Landlord has dealt with no broker in connection with this Amendment other than Jones Lang LaSalle. Landlord agrees to indemnify and hold Tenant harmless from all claims of any other brokers claiming to have represented Landlord in connection with this Amendment. Landlord shall pay a commission to Jones Lang LaSalle pursuant to a separate written agreement.

		
	22.5
	Each of the parties hereto represents that the person signing this Amendment has the authority to execute and deliver the same on behalf of the party hereto for which such signatory is acting and further each of Landlord and Tenant represent that they have obtained all required approvals to enter into this Amendment. Tenant hereby  represents  and warrants that neither Tenant, nor any persons or entities holding any  legal  or  beneficial interest whatsoever in Tenant,  are  (i) the target  of  any  sanctions program  that is established by Executive Order of the President or published by the Office of Foreign Assets Control, U.S. Department of the Treasury ("OFAC"); (ii) designated by the President or OFAC pursuant to the Trading with the Enemy Act, 50 U.S.C. App. § 5, the International  Emergency  Economic  Powers  Act,  50 U.S.C.  §§  1701-06, the Patriot Act, Public Law 107-56, Executive Order 13224 (September 23, 2001) or any Executive Order of the President issued pursuant to such statutes; or (iii) named on the following list that is published by OFAC: "List of Specially Designated Nationals and Blocked Persons." If the foregoing representation is untrue at any time during the Term and/or the Building D Term, an event of default under the Lease will be deemed to have occurred, without the necessity of notice to Tenant. Landlord hereby represents that Landlord is not the target of any sanctions program that is established by Executive Order of the President or published by OFAC; (ii) designated by the President or OFAC pursuant to the Trading with the Enemy Act, 50 U.S.C. App. § 5, the International Emergency Economic Powers Act, 50 U.S.C. 

§§ 1701-06, the Patriot Act, Public Law 107-56, Executive Order 13224 (September 23, 2001) or any Executive Order of the President issued pursuant to such statutes; or (iii) named on the following list that is published by OFAC: "List of Specially Designated Nationals  and Blocked Persons."

		
	22.6
	Pursuant to California Civil Code Section 1938, Landlord hereby notifies Tenant that as of the date of this Amendment, The Campus have not undergone inspection by a "Certified Access Specialist" to determine whether The Campus meet all applicable construction­ related accessibility standards under California Civil Code Section 55.53. To allow for compliance with building performance benchmarking and disclosure regulations, and to facilitate implementation of sustainable improvements to the Buildings, Tenant shall: (a) retain copies of its "utility data", which includes, but is not limited to, Tenant's utility bills and invoices pertaining to Tenant's energy, water, and trash usage at the Building during the Term (as the same may be further extended), and (b) upon request, provide Landlord with copies of such "utility data". Tenant further agrees, upon Landlord's request, to execute utility release fo11ns provided by the applicable utility or municipality to expedite the data collection process.

		
	22.7
	For purposes of the Landlord Work (Exhibit B) and Tenant Work (Exhibit C), Landlord's Notice Address shall include the following:

Greg Carey
Project Director Embarcadero Capital Partners LLC 1301 Shoreway Road, Suite 250
Belmont, California 94002-4151

		
	22.8
	Tenant's Notice Address for all notices under the Lease are as follows:

GoPro, Inc.
3000 Clearview Way
San Mateo, CA 94402
Attn: General Counsel

With a copy to:

GoPro,Inc
3000 Clearview Way,
San Mateo, CA 94402
Attn: Vice President, Workplace

And with a copy to:
Jones Lang LaSalle
4085 Campbell Avenue, Suite 150 Menlo Park, CA  94025
Attn: Rich Branning, Managing Director

[REMAINDER OF PAGE INTENTIONALLY  LEFT  BLANK]

		
	22.9
	Redress for any claim against Landlord under the Lease and this Amendment shall be  limited to and enforceable only against and to the extent of Landlord's  interest  in the Project. The obligations of Landlord under the Lease are not intended to and shall not be personally binding on, nor shall any resort be had to the private properties of, any of its trustees or board of directors and  officers,  as the case may  be,  its investment  manager,  the general partners thereof, or any beneficiaries, stockholders, employees, or agents of Landlord or the investment manager, and in no case shall Landlord be liable to Tenant hereunder for any lost profits, damage to business, or any form of special, indirect or consequential  damages.

IN WITNESS WHEREOF, Landlord and Tenant have entered into  and  executed  this  Amendment  as of the date first written  above.
LANDLORD:

RAR2-CLEARVIEW BUSINESS PARK OWNER, LLC,
a Delaware  limited liability company

By: RAR2-Clearview Business Park Member QRS, LLC,  a Delaware limited
liability company, its Investor Member and Manager

By: RREEF America,  L.L.C., 
a Delaware limited liability
its Authorized Agent

By: /s/ Lisa Vogel
Name: Lisa Vogel
Title: Vice President
Dated: November 23, 2015

TENANT: GOPRO, INC.,
a Delaware corporation

By: /s/ Jack Lazar
Name: Jack Lazar
Title: Chief Financial Officer
Dated: November 20, 2015

EXHIBIT A - OUTLINE AND LOCATION OF BUILDING D EXPANSION SPACE

attached to and made a part of the Amendment dated as of November 23, 2015, between RAR2-CLEARVIEW  BUSINESS PARK OWNER, LLC, a Delaware  limited liability company,    as Landlord,  and GOPRO, INC., a Delaware corporation, as Tenant

Exhibit A is intended only to show the general layout of the Building D Expansion Space as of the beginning of Building D Expansion Effective Date. It does not in any way supersede any of Landlord's rights set forth in the Lease with respect to arrangements and/or locations of public parts of the Building and changes in such arrangements and/or locations. It is not to be scaled; any measurements or distances shown should be taken as approximate.

(attachment not included due to HTML conversion issues)

{2011-9599/00572913;8}                    A-1

EXHIBIT B - LANDLORD WORK

attached to and made a  part of the Amendment dated as of November 23, 2015, between RAR2-CLEARVIEW  BUSINESS PARK OWNER,  LLC, a Delaware  limited liability company,  as Landlord, and GOPRO, INC., a Delaware corporation, as Tenant

Landlord, at Landlord's sole cost and expense, shall ensure that the Building D Expansion Space is  in  "warm shell" condition as described below and detailed in accordance with the plans prepared by KSH Architects and the most current Drawing Set, dated September 30, 2015, referencing the Current Permit Drawing List is attached hereto as Exhibit B-1. The improvements shall be built by  Landlord sustantially in accordance with the foregoing Drawing Set are hereinafter referred to as the "Landlord Work." Any other work to be completed in excess of the  specifications  set  forth  below  and/or  the attached Current Permit Drawing List or any changes to the specifics set forth below and/or the Current Permit Drawing List requested by Tenant or necessary to accommodate any of Tenant's construction hereunder  "Tenant Work," as defined  in Exhibit C.

Warm  Shell Description

General Details
		
	Property Name   
	Clearview Business Park

		
	Street Address
	3025 Clearview Way,  San Mateo,  CA 94402

		
	Zoning
	E1 - Executive Park

		
	Usage
	Office

		
	Occupancy Class
	Group B Business

		
	Ceiling Height
	Varies: 9'-6"(2nd and 3rd floors) and 11'-0"(ground floor)

		
	Overall Building Height
	53'

		
	Type of Construction
	Type IIB sprinklered

		
	Structure 
	The foundation systems consist of a combination of  concrete retaining walls, grade beams, spread footings and tension micropiles which support  structural steel columns, beams and brace frames.

		
	Column Spacing 
	The building has three bays. Column spacing at the two perimeter bays is 39'9" x 30'0" (typ.). The middle bay has column spacing at 25' 6" x-30'0-".

Building Exterior    The  building exterior finishes consist of tinted glass, metal panel and precast concrete.
		
	Roofing
	The roof profile has a perimeter sloped mansard element with composite shingles to match the other buildings at Clearview. It is supported by a light-gauge metal frame. Lightweight insulating concrete is used on the flat sections of the roof. Landlord  is  installing lightweight insulating concrete. Tenant  and  Landlord  shall mutually confirm if R Value is satisfactory for occupancy  of the upper floors.

		
	Building Interior 
	Interior scopes of work include the main entry lobby, elevator lobbies on each floor,  restrooms  and shower  facilities.  The two-story main entry lobby includes a clear glass storefront, stone cladding, wood veneer and painted wall finishes with thin-set tile flooring to match the aesthetic of other building lobbies on the campus. Restrooms and showers have a combination of floor tile, accent wall tile and painted wall finishes with stone counte1iops and stainless steel partitions. Elevator lobbies have painted walls and ceilngs and porcelain floor tile. 

		
	Number of Stairs 
	There are two sets of interior stairs which are concrete-filled metal pan stairs. Metal tube handrails are provided. Stair enclosures are fully furnished and consist of painted gypsum board walls and ceilings.

		
	HVAC 
	HVAC is supplied by two (2) 110 ton rooftop VAV cooling only units (high efficiency, 100% outside air economizer). There are two (2) 1000 MBH heating hot water boilers and two (2) hot water distribution pumps with variable frequency drives. One (1) pump shall be standby. Return is non-ducted via ceiling plenum. Toilet exhaust system shall be ducted to a roof mounted exhaust fan. There will be a split system DX fan coil unit for elevator control/machine room. There will also be elevator relief vents and boiler and water heater flue vents. Vertical distribution of all utilities to be complete, stubbed and valved to each floor. Any provisions for Tenant required supplemental HVAC would be part of T.I.'s.

(Horizontal distribution system is not included in the Warm Shell scope. It shall be installed as part of the tenant improvements and shall be variable air volume (VAV) _with hot water reheat.)

		
	Utilities
	Electric:Pacific Gas & Electric Water & Sewer: City of San Mateo Gas:

Pacific Gas & Electric
Telephone:AT&T
Trash: Recology
		
	Plumbing
	Domestic water service is provided each building through water service entrance with backflow preventer waste service to be provided to each floor. Waste and vent provisions for Tenant kitchens, break rooms etc. shall be available for Tenant to distribute from toilet core areas. Domestic water to be stubbed and valved to each floor.

		
	Electrical Systems
	Power is supplied to Building D through a utility-owned pad- mounted transformer to a 2500-Amp, 277/480-volt, 3-phase, 4- wire Main Switchboard in the main electrical room on the ground floor. Power for the building's (2) AC units is supplied by the main switchboard.

A 400-Amp 480-volt, 3-phase, 3-wire Distribution Panel in the roof ·penthouse provides power to the building's (2) elevators  as well as mechanical and receptacle loads throughout the roof area.
    
(2)  l" conduits  are routed  from the main electrical room to the building exterior for future electric vehicle charging stations. Electrical infrastructure as pertains to Tenant Space lighting and Plug load as described below. It is the Tenant's understanding that provisions for any emergency generator(s) would not be included in the Warm Shell.
Lighting: A 33kW/33KVA Inverter located in the main electrical room provides power to (3) emergency lighting panels - (1) on each level.
A 400-Amp 277/480-volt, 3-phase, 4-wire Distribution Panel on the ground floor provides power to (4) 100-Amp 277/480-volt lighting panels - (1) at each level and (1) for site lighting. Sufficient power for l .SW/sf of lighting.
Lighting Control Panels, located in west electrical rooms on each floor, provide independent control for each whole floor. Control capabilities include time clock and demand response as required by Title 24.
Restroom lighting is LED and controlled via local occupancy sensors.
Building Lobby/Elevator Lobby lighting is LED and controlled via local occupancy sensors.
24/7 stairwell lighting is provided by wall mounted LED linear fixtures with integral occupancy sensors.
Exit signage throughout is edge-lit LED with integral battery backup.
Roof/Exterior lighting controlled by integral photocell and through lighting control panel to provide scheduled auto-off as required by Title 24.
Tenant Space - Plug Load: Provisions for power to each floor consists of (2) 7SKVA K-13 transformers - (1) at each finished electrical room core - each supplying a 225-Amp 277/480-volt, 3- phase, 4-wire 3-section panelboard. l SOKVA total capacity per level sufficient for 4.9 W/sf of tenant plug load. The Warm Shell includes (8) 6" underground conduits stubbed into the 1st floor MPOE and then (6) 4' sleeves in the telephone room on each floor and (2) 4' sleeves on the roof.
		
	Vertical Transportation
	The building has two (2) MRL traction passenger elevators which would be finished to a quality of equal or better of 3500 lbs @ 200 feet per minute.

		
	Fire/Life Safety Systems
	The Warm Shell includes protected by an addressable fire alarm panel that monitors initiation devices and, if alarmed, signals notification devices. Panel provided to Landlord to have adequate capacity to handle  tenant  improvement  devices for a class A office building. Devices within the Tenant spaces would be part of the  tenant  improvements.  The building is fully  sprinklered  with a wet fire sprinkler system.    

		
	Sustainability
	The building was designed to LEED Silver standards.  The project  has  been  registered  with  USGBC  by  Thornton  Tomasetti  (LEED consultant) in anticipation of certifying the building.    

[REMAINDER  OF PAGE  INTENTIONALLY  LEFT BLANK]

EXHIBIT B-1 - CURRENT PERMIT DRAWING LIST

attached to and made a part of the Amendment dated as of November6 2015, between RAR2-CLEARVIEW BUSINESS PARK OWNER, LLC, a Delaware limited liability company, as
Landlord, and GOPRO, INC., a Delaware corporation, as Tenant

Page 1of 4

	
		
	3025 CLEARVIEW - llUILDING D

sheet Humber + Name
	current Drawingset (09.30.15)

sheet Date

	ARCHITECTURAi. - KORTH SUNSERI HAGEl' ARCHITECTS
	 

	AO.O    PROJECT ltlFORMATION
	6/22/2015

	A0.2    CONDITIONS OF APPROVAL
	2/10/20:15

	A0.3    CONDITIONS OF APPROVAL
	2/10/20:15

	A0.4    CONDJTJON5 OF APPROVAL
	2/10/20:15

	A0-5  EXITING REQ_UIREMENTS
	2/10/2015

	A0.6   RESTROOM DETAIL:5
	2/10/2015

	A0.7    ACCi:SSIBIUTY DETAILS
	4/15/2015

	A0.8   CAL GREEN CHECKLIST
	4/15/2015

	Al.O    OVER-"J..L51TE PLAN
	2/10/20:15

	A1.1   PROJECT SITE  PLAN
	4/15/2015

	Ai 2  ENI.All.GED TllA5H ENCLOSURE
	2/10/2015

	AZ.1   FIRST fLOOR PLAN
	2/10/2015

	A2.2  SECOND FLOOR Pl.AN
	2/10/201.5

	A2.3  THIRD FLOOR PlAN
	2/10/2015

	A2.4    ROOF PLAN
	6/22/20:15

	A3.1 ELEVATIONS
	2/10/2015

	A3.2  ELEVATIONS
	2/10/2015

	A3.3    ELEVATIONS
	2/10/2015

	A3.10 BU!LDNG SECTIONS
	2/10/2015

	A4.1 FIRST fLOOR5LAB PLAN
	2/10/2015

	A4.2    SECOND FLOOR SLAB PLAN
	2/10/2015

	A4.3    THIRD FLOOR SLAB PLAN
	2/10/20:15

	A4.4    ROOF SLAB PLAN
	2/10/2015

	AS.10 ENLARGED RESTROOM PLANS
	2/10/2015

	AS.11 ENLARGED RESTROOM & SHOWER PLANS & ELEVATIONS
	2/10/2015

	AS.12  ENLARGED RESTROOM DETAIL:5
	2/10/2015

	AS.13   ENLARGED BUILDING LOBB\' FLOOR PlAN
	2/10/2015

	AS.14 ENLARGED BUILDING LOBBY RCi>
	2/10/2015

	AS.15 INTERIOR ELEVATIONS BUILDlNG LOBBY
	2/10/2015

	AEk1   REFLECTED CEIi.iNG PLAN
	2/10/2015

	A 6.2    REFLECTED Ci:ILING PLAN
	2/10/20:l.5

	A6.3   REFLECTED CEILING Pl.AN
	2/10/2015

	Ali.4   REfLECTED CEILING PLAN
	2/10/2015

	A7.0   5TAHl 1
	2/10/2015

	A7.1  STA!R 2
	2/10/2015

	A7.2    ENI.All.GED ELEVATOR SECTION
	2/10/2015

	A8.1 ENLARGED SECTION
	2/10/2015

	A8.2   ENLARGED SECTION
	2/10/2015

	A!l 3   ENLA.RGED SECTlON
	2/10/2015

	A8.4    ENI.All.GED SECTION
	2/10/2015

	An.:w   ENLARGED DETAIL:5
	2/10/2015

	A!l 21 ENLA.RGED DETAILS
	2/10/2015

	A9.1 ENLIII\GED DETAILS
	2/10/2015

	A:l.0.1 DOOi\ SCHEDULE & DETAILS
	2/10/20:15

	A10.2   PARTITION SCtiEDULE
	2/10/2015

	A10.3   PARTITION DETAILS
	2/10/2015

	A10.4   PARTITION DETAILS
	2/10/20:15

	A10.5   PARTITION DETAILS
	2/10/2015

	 
	 

	CIVIL - KIER & WRIGHT
	 

	C1.0  COVERSHEET
	6/23/2015

	Ci.1 DETAILS
	2/10/2015

	C2.0  TOPOGRAPHIC SURVEY
	2/10/2015

	C2.1 HORIZONTAL CONTROL Pl.AN
	x-xx-xx

	 
	 

Page 2 of 4

	
		
	C3.0  GRADING & DR.ll1NAGE PLAN
	6/23/2015

	C:U   UTILITY Pl..llN
	6/23/2015

	C4.0  STORMW.ll TER MANAGEMENT PLAN
	6/23/2015

	C5.0 EROSION CONTROL PLAN
	6/23/2015

	C6.0   DEMOLITION Pi.llN
	 

	 
	 

	JOINT TI\ENCti PLANS - RGA DESIGN
	 

	JT-UOINTTRENCH TITLE SHEET
	2/10/2015

	JT-2JOINTTRENCH INTENT
	2./10/2015

	JT-5 JOIITT TRENCH tiNTEITT
	2/10/2015

	 
	 

	I.ANDSCAPE - THE GUZZARDO PARTNERSHIP, INC.
	 

	1.1.1   NOTES AND LEGENDS
	2/10/2015

	ll.2    PLANTING NOTES .lNl  D LEGENDS
	2/10/2015

	1.2.1   LAYOUT PLAN
	2/1012015

	B.1 FlNE GRADING PLAN
	2/10/2015

	1.4.1   PLANTING PLAN
	2/10/2015

	1.5.1     IRRIGATION PLAN
	2/10/2015

	1.5.2  IRRIGATION NOTES AND LEGEND
	2/10/2015

	1.5.3  IRRIGATION DETAILS
	2/10/2015

	1.6.1  CONSTRUCTION  DET.ll LS
	2/10/2015

	1.7.1  TREE Dl5P0SIT10N Pl.AN
	4/15/2015

	1.7.2   TREE PROTECTION NOTES
	4/15/2015

	 
	 

	STRUCTURAL-  NISHKIAN MENNINGER
	 

	S0.1     GUIERAL NOTES
	4/15/2015

	S0.2Gl:NEI\AL NOTES
	4/15/2015

	S0.3GENERAL NOTES
	2/10/2015

	S0.4LOADING DIAGRAMS
	2/10/2015

	Si.:!.TYPICt.J. DETAILS
	2/10/2015

	S1.2TYPIC.AJ. DETAILS
	2/10/2015

	S1.3TYPIC.AJ. DETAILS
	2/10/2015

	S2.0LOWER LEVEL FOUNDATION Pi.llN
	2/10/20'15

	S2.1     LEVEL 1FOUNDATION/ FRAMiNG Pl.AN
	2/10/2015

	52.1.1  MICROPILE LOADlrtG PLAN
	6/5/2015

	52.2LEVEL 2 FRAMING PLAN
	2/10/2015

	S2.3LEVEL 3 FRAMING PLAN
	2/10/2015

	S2.4ROOF FRAMING PLAN
	2/10/2015

	S2.5MANSARD/ PENTHOUSE ROOF FRAMING  PLAN
	2/10/2015

	S3.1      BM.CE FRAME ELEVATIONS
	2/10/2015

	53.2BM.CE FRAME DETAILS
	2/10/2015

	S3.3BM.CE FRAME DETAILS
	2/10/2015

	53.4BM.CE FRAME DETAILS
	2/10/2015

	53.5BM.CE FRAM!: DETAILS (NIPPON)
	2/10/2015

	53.6B!RltCE FRAME DETAILS (NIPPON)
	2/10/2015

	S3.7BM.CE FRAME DETAILS (NIPPON)
	2/10/2015

	53.llBM.CE FRAME DETAILS (NIPPON)
	2/10/2015

	54.1  FOUNDATION DETAILS
	2/10/2015

	S4.2FOUNDATION DETAILS
	12/a/2014

	S4.5FOUNDATION DETAILS
	2/10/2015

	Sil.4FOUNDATlmlDETAILS
	2/10/2015

	S/1.5FOUNDATION DETAILS
	2/10/2015

	S/1.6FOUNDATION DETAILS
	2/10/20'15

	S4.7FOUNDATION DETAILS
	2/10/2015

	S5.1STEEL DETAILS
	2/10/2015

	S5.2STEEL DETAILS
	2/10/2015

	S5.:!STEEL DETAILS
	2/10/2015

	S5.4STEEL DET.llJLS
	2/10/2015

	S5.5STEEL DETAILS
	2/10/2015

Page 3 of 4

	
			
	S5.6
	STEEL DET.6JLS
	2/10/2015

	S5.7
	STEEL DET.6JLS
	2/10/2015

	55.ESTEEL DETAlLS
	2/10/2015

	S6.1
	PRELIMINARY PRECAST Pt.NEL SUPPORT DETAILS
	2/10/2015

	57.1METAL STUD DETAILS
	2/10/2015

	57.2METAL STUD DETAILS
	2/10/2015

	56.1TRASH ENCLOSURE
	2/10/2015

	 
	 

	MECHANICAL· CRITCHFIELD MECHANICAL INC.
	 

	M0.0
	INDEX  NOTES, SCHEDULE LEGEND
	2/10/2015

	M2.1
	FIRST FLOOR HVAC PLAN
	2/10/2015

	M2.2.
	SECOND FLOOR HVAC PLAN
	2/10/2.015

	M2.:i
	THIRD FLOOR HVAC Pl.toll
	2/10/2015

	M2.4
	ROOF HVAC EO.UIPMENT Pl.AN
	2/10/2015

	M2.4C
	COORDINATION  PLAN, EQUIPMENT Pl.toN
	2/10/2015

	M3.1
	RIDER !liAGRAM
	2/10/2015

	M4.1
	HVAC DETAILS
	2/10/2015

	MS.1
	PIPING DIAGRAM5 AND DETAILS
	2/10/2015

	M6.1
	WIRING DIAGRAM5
	2/10/2015

	MT24.1 TITLE 24
	2/10/2015

	MT24.2.  TITLE 24
	2/10/2015

	MT24.3  TITLE 24
	2/10/2015

	 
	 

	ElEGTRICAL CUPE:!\TINO ELECTRIC !NC.
	 

	1:0.00
	IN_DE)( AND NOTES
	4/15/2015

	E0.10
	LEGEND
	2/10/2015

	E0.20
	LUMINARE SctiEDULE & TITLE 24
	2/10/2015

	E0.30
	TITLE 24
	2/10/2015

	E0.31
	TITLE 24
	2/10/2015

	E0.32
	TITLE 24
	2/10/2015

	E0.33
	TITLE 24
	2/10/2015

	E0.34
	TITLE 24
	2/10/2015

	E0.40
	FUDER & TRANSFORMER SCHEDULE5
	2/10/2015

	1:1 00
	S!NGLE UNE DIAGRAM
	2/10/2015

	1:1.01
	TELECOM & GROUNDING RISER DIAGRAM
	2/10/2015

	E2.00
	OVERAU.SITE PlAN
	2/10/2015

	l:3.01
	POW!'R PLAN· I.EVEL 1
	2/10/2015

	f3.02
	POW!'R Pl.AN_ - 1.EVEL 2
	2/10/2015

	B.03
	POWER PLAN  LEVEL 3
	2/10/2015

	E3.04
	POW!'R Pl.AN  ROOF
	2/10/2015

	E3.05
	ENLARGED ELECTRICJ..L PLANS
	2/10/2015

	E4.01
	LIGHTING PLAN· LEVEL 1
	2/10/2015

	1:4.02
	LIGHTING PLAN· LEVEL 2
	2/10/2015

	1:4.03
	LIGHTING PLAN· LEVEL 3
	2/10/2015

	E4.04
	LIGHTING PLAN· ROOF
	2/10/2015

	E6.00
	PANELSCliEDULES
	2/10/2015

	E6.01
	PANELSCliEDULES
	2/10/2015

	E6.02
	PANEL SCHEDULES
	2/10/2015

	1:6.03
	PANELSCliEDULES
	2/10/2015

	E700
	LIGHTING CONTROL DETAILS
	2/10/2015

	Ell.OD
	SITE PHOTOMETRIC PLAN
	4/15/2015

	 
	 

	PLUMBING·!.'OS PLUMBING INC.
	 

	P0.0
	INDEX, !.!:GENO & SCliEDULE
	1/26/2015

	P2..1U
	PLUMBING f lRST FLOOR PLAN UNDERGROUND
	1/26/2015

	P2..1
	PLUMBING FIRST FLOOR PLAN PIPING
	1/26/2015

	P2..2
	PLUMBING SECOND FLOOR PLAN
	1/26/2015

	P2..3
	PLUMBING Ti11RD FLOOR PLAN
	1/26/2015

	P2..4
	PLUMBING ROOF PW!
	1/26/2015

I

Page 4 of 4

	
		
	P:,.1 PLUMBING ENLARGED FIRST FLOOR PLJ> l
	1/26/2015

	P:,.2PLUMBING ENLARGED SECOND & TiilRD FLOOR PLANS
	1/26/2015

	P4.1    PLUMBING DIAGRAMS
	1/26/2015

	P4.2PLUMBING  DIAGRA MS
	1/26/2015

	 
	 

	FACADE ACCE.SS- OL\'MPIOUE FAC..!tOE ACCES5  CONSULTING
	 

	fAO.O  COVER SHEET
	12/8/2014

	FA2.1  FIRST FLOOR PLAN
	12/S/2014

	FA2.4    ROOFPL.!tN
	12/8/2014

	FA3.1 ELE\IATIOrlS
	12/8/2014

	fA3.2   ELEVATIOrlS
	12/8/2014

	fAS.0    WALL SECTION
	12/6/2014

	fAB.1  51:CTION AND OETAl!.5
	12/6/2014

	f'AlO.O  DETAJ!.5
	12/8/2014

	 
	 

	ELEVATOR· SYSKA HENNESSY GROUP
	 

	VT2SECTION AND PLANS
	no date

[REMAINDER  OF PAGE INTENTIONALLY  LEFT  BLANK]

EXHIBIT B-2 -PRELIMINARY  CONSTRUCTION SCHEDULE

attached to and made a part of the Amendment dated as of November 2015, between RAR2-CLEARVIEW BUSINESS  PARK  OWNER, LLC, a Delaware  limited  liability  company, as Landlord, and GOPRO, INC., a Delaware corporation, as Tenant

(attachment not included due to HTML conversion issues)

EXHIBIT C - TENANT WORK

attached to and made a part of the Amendment dated as of November  ,2015, between RAR2-CLEARVIEW  BUSINESS  PARK  OWNER, LLC, a Delaware  limited  liability  company, as
Landlord, and GOPRO, INC., a Delaware corporation, as  Tenant

		
	I.
	Building D Expansion Space.

1.General. Tenant, following the delivery of the Building D Expansion Space by Landlord and the  full and final execution and delivery of the Amendment to which this  Exhibit  C  is  attached  and  all prepaid rental and insurance certificates required under the  Lease,  as  amended  hereby,  shall  have  the right to perform alterations and improvements in the Building D Expansion Space (the "Tenant Work"). Notwithstanding the foregoing, Tenant and its contractors shall not have the right to perform the Tenant  Work in the Building D Expansion Space unless and until Tenant has complied with all of the terms and conditions of Article 9 of the Original Lease, including, without  limitation,  approval by  Landlord  of the final plans  and  construction  documents  for the Tenant Work and the contractors to be retained by Tenant  to perform such Tenant Work, such approval not to be unreasonably withheld, conditioned or delayed.  Tenant shall be solely liable for all costs and expenses associated with or otherwise caused by Tenant's performance and installment of the Tenant Work (including, without limitation, any legal compliance requirements arising outside of the Building D Expansion Space), subject to reimbursement  from the  Test  Fit and Building D Allowances (each as  defined  below).  Tenant  hereby  acknowledges  and  agrees that  the Property is subject to a collective bargaining or such  other  similar  agreement.  If Tenant  shall engage any contractor and such contractor or any subcontractor of  such contractor  shall employ  any non-union labor or supplier, Tenant shall be responsible for and hold Landlord harmless from any and all delays, damages and extra costs suffered by Landlord as a result of any dispute with any labor unions  concerning  the wage, hours, terms or conditions of the employment  of any such labor.

2.Architect. Tenant shall retain an architect (approved by Landlord, which approval shall not be unreasonably withheld) (the "Architect") for the development of architectural plans and drawings for the Tenant Work. Tenant has selected and Landlord hereby approves of KSH Architects as the Architect for construction of the Tenant Work and the Campus Work. Tenant reserves  the  right  to  modify  their  selection of architect. Any architectural firm change shall be presented to Landlord in advance and  in  writing for Landlord's final approval, such approval not to be unreasonably withheld, conditioned  or  delayed. Tenant shall enter into a contract  with the Architect  for the development  of architectural  plans  and  drawings for the Tenant Work and the Campus Work collectively.

3.Contractor Selection Process. Landlord's approval of the  contractors  to  perform  the  Tenant Work shall not be unreasonably withheld, conditioned or delayed. The parties agree  that  Landlord's  approval of the general contractor to perform the  Tenant  Work  shall  not  be  considered  to  be unreasonably withheld if any such general contractor (a) does not have trade references reasonably  acceptable  to Landlord,  (b) does not  maintain  insurance  as required  pursuant  to the terms  of the    Lease, (c) does not have the ability to be bonded for the work in an amount of no less than  one hundred  fifty percent (150%) of the total estimated cost of the Tenant Work, (d) does not provide current financial statements reasonably acceptable to Landlord, (e) does not execute the Responsible Contractor Policy Statement provided by Landlord, or  (f) is not  licensed  as a contractor  in the  state/municipality  in which the Building D Expansion Space is located. Tenant acknowledges the foregoing is not intended to be an exhaustive list of the reasons why Landlord may reasonably withhold its consent to a general contractor. Tenant shall enter into a direct contract for the Tenant Work with a general contractor selected by  Tenant  and  approved  by  Landlord,   such  approval  not  to  be  unreasonably  withheld,  conditioned  or  delayed. Landlord's designated electrical contractor, HVAC contractor and life safety contractors shall be permitted to bid on the electrical, HVAC and life safety portions of the Tenant Work (respectively). Tenant would reserve the right to require the general contractors to bid specific trades to a minimum of two to three subcontractors. In addition, Landlord 

shall have the right to reasonably approve of the architect preparing the Construction Documents (defined below) and any subcontractors used in connection with the Tenant Work. Notwithstanding the foregoing, however, Tenant shall be responsible for the reasonable cost of third party examination of Tenant's plans for non-standard office improvements, including, but not limited to, review by structural, mechanical or MEP engineer, and such costs shall be deducted from the Building D Allowance (as hereinafter defined). In addition, Tenant also reserves the right to pre-select a general contractor based on fee and general condition negotiations, subject to Landlord's prior reasonable approval of general contractor.

		
	4.
	Construction Documents.

(a)Space Plan. Tenant and the Architect shall prepare a final space plan for the Tenant Work in the Building D Expansion Space (collectively, the "Final Space Plan"), which Final Space Plan shall include a layout and designation of all offices, rooms and other partitioning, their intended use, and equipment to be contained therein, and shall deliver four (4) copies signed by Tenant of the Final Space Plan (in "half size" hard copy paper and also in PDF format) to Landlord for Landlord's approval. Landlord shall approve or disapprove any draft of the Final Space Plan within seven (7) business days after Landlord's receipt thereof (provided however that such seven (7) business day period shall be extended as needed for structural items). Landlord's failure to respond within such seven (7) business day period shall be deemed Landlord's disapproval of the Final Space Plan; provided, however, that after the expiration of such seven (7) business day period, Tenant may send Landlord written notice of the expiration of such seven (7) business day period with a second request for Landlord to so approve of the Final Space Plan, in which case, Landlord shall be deemed to have approved of the Final Space Plan (other than for structural matters) if Landlord does not approve or disapprove of the Final Space Plan within five (5) business days after receipt of such written notice from Tenant. If Landlord disapproves any draft of the Final Space Plan, Landlord's disapproval shall indicate the reasonable reasons for such disapproval and Tenant shall resubmit the Final Space Plan with the modifications required by Landlord. This process shall continue until the Final Space Plan is approved by Landlord. Other than for structural items, Landlord shall respond with its approval or disapproval of the resubmitted Final Space Plan within five (5) business days following Landlord's receipt thereof. Landlord's failure to respond within such within five (5) business day period shall be deemed Landlord's disapproval of the resubmitted Final Space Plan; provided, however, that after the expiration of such within five (5) business day period, Tenant may send Landlord written notice of the expiration of such within five (5) business day period with a second request for Landlord to so approve of the Final Space Plan, in which case, Landlord shall be deemed to have approved of the Final Space Plan other than for structural items if Landlord does not approve or disapprove of the Final Space Plan within five (5) business days after receipt of such written notice from Tenant.

(b)Final Working Drawings. Upon Landlord's approval  of  the  Final  Space  Plan,  Tenant shall cause the Architect to complete the architectural and engineering drawings for the Premises, and the final architectural working drawings in a form which is complete to  allow  subcontractors  to  bid  on the work and to obtain all applicable permits (collectively, the "Final Working Drawings") and shall submit two (2) full size sets signed by Tenant of the same and the CAD file of the Final Working Drawing to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. Within fifteen (15) days following Landlord's receipt of the Final  Working Drawings, Landlord shall provide  Tenant with its approval,  disapproval  or  approval with  conditions  of such Final   Working Drawings (provided however that such fifteen (15) day period shall be extended as needed for structural items). Landlord's failure to respond within such fifteen (15) day period shall be deemed Landlord's disapproval of the Final Working Drawings; provided, however, that after the expiration of such   fifteen (15) day period, Tenant may send Landlord written notice of the expiration of such fifteen (15) day period with a second request for Landlord to so approve of the Final Working Drawings, in which case, Landlord shall be deemed to have approved of the Final Working Drawings (other than for structural items) if Landlord does not approve or disapprove of the Final Working Drawings within five (5) days after receipt of such written notice from Tenant. If Landlord disapproves any draft of the Final Working Drawings, Landlord's disapproval shall indicate the reasonable reasons for such disapproval and Tenant shall resubmit the Final Working Drawings with the modifications required by Landlord. This process shall continue until the Final Working Drawings are approved by Landlord. Landlord shall respond with its approval or disapproval of the resubmitted Final Working Drawings within ten (10) business days following Landlord's receipt thereof. Landlord's failure to respond within such ten (10) business day period shall be deemed Landlord's disapproval of the resubmitted Final Working Drawings; provided, however, that after the expiration of such ten (10) 

business day period, Tenant may send Landlord written notice of the expiration of such ten (10) business day period with a second request for Landlord to so approve of the resubmitted Final Working Drawings, in which case, Landlord shall be deemed to have approved of the resubmitted Final Working Drawings (other than for structural items) if Landlord does not approve or disapprove of the resubmitted Final Working Drawings within five (5) business days after receipt of such written notice from Tenant. Tenant shall be solely responsible for the timely preparation and submission to Landlord of the final architectural, electrical and mechanical construction drawings, plans and specifications (called "Construction Documents") necessary to construct the  Tenant Work, which Construction Documents shall be subject to approval by Landlord, such approval not to be unreasonably withheld, conditioned or delayed, and Landlord's architect and engineers and shall comply with their requirements to avoid aesthetic or other conflicts with the design and function of the balance of the Project. Tenant shall be responsible for all elements of the design of the Construction Documents (including, without limitation, compliance with law, functionality of design, the structural integrity of the design, the configuration of the Building D Expansion Space and the placement of Tenant's furniture, appliances and equipment), and Landlord's approval of the Construction Documents shall in no event relieve Tenant of the responsibility for such design. Tenant shall be solely responsible for the timely preparation and submission of the Construction Documents and for all elements of the design of such Construction Documents and for all costs related thereto.

(c)Permits. The Final Working Drawings shall be approved by Landlord (the "Approved Construction Documents") prior to the commencement of the construction of the Tenant Work. Tenant shall cause the Architect to promptly submit the Approved Construction Documents to the appropriate municipal authorities for all applicable building permits necessary to allow its general contractor to commence and fully complete the construction of the Tenant Improvements.

5.Scope of Tenant Work. Subject to Landlord's review and approval of Tenant plans and specifications therefor, the Tenant Work may include (at Tenant's election):

(a)Installation of communication conduit;
(b)Installation of Tenant's Security System at the main entrance to Building D for after- hours access; and
(c)Integration of Tenant's telephone systems with Building D's emergency generator, if applicable.
Any portion  of the  Tenant Work that may tie  into the Building D electronic,  environmental,  fire, life 
and/or other building systems shall be compatible therewith and the cost of such evaluation shall be deducted from the Building D Allowance.

		
	6.
	Building D Allowance.

(a)Landlord shall provide Tenant with  a test fit allowance  in the amount  of $11,087.60 (that  is, $0.10 per rentable square foot of the Building D Expansion Space) (the "Test  Fit  Allowance").  In addition, Landlord agrees to contribute the sum of $7,206,940.00 (that is, $65.00 per rentable square feet of  the Building D Expansion Space) (the "Building D Allowance") toward the cost of pe1forming the Tenant Work in preparation of Tenant's occupancy of the Building  D  Expansion  Space.  The  Building  D  Allowance may only be used for the cost of preparing design and construction  documents  and mechanical  and electrical plans for the Tenant Work and for hard costs in connection with the Tenant Work. Landlord shall have no obligation to disburse any portion of the Test Fit Allowance, the Building D Allowance and/or the Campus Allowance  during any period when Tenant is in breach or default of the Lease, as   amended.
(b)The Building D Allowance, less a ten percent (10%) retainage (which retainage shall be payable as part of the final draw), shall be paid to Tenant or, at Landlord's option, to the order of the general contractor that performs the Tenant Work, in periodic disbursements within thirty (30) days after receipt of  the following documentation:
(i)an application for payment and sworn statement of contractor substantially in the form of AIA Document G-702 covering all work for which disbursement is to be made to a date specified therein;
(ii)a certification from an AIA architect substantially in the form of the Architect's Ce1iificate for Payment which is located  on AIA Document  G702, Application and Certificate  of Payment;
(iii)contractor's, subcontractor's and material supplier's unconditional waivers of liens which shall cover all Tenant Work for which disbursement is being requested and all other statements and 

forms reasonably required for compliance with the mechanics' lien laws of the state of California, together with all such invoices, contracts, or other suppmiing data as Landlord or Landlord's Mo1igagee may reasonably require;
		
	(iv)
	a cost breakdown for each trade or subcontractor performing the Tenai1t  Work;

(v)a request to disburse from Tenant containing an approval by Tenant of the  work done and a good faith estimate of the cost to complete the Tenant  Work.
(c)Upon completion of the Tenant Work, and prior to final disbursement of the Building D Allowance,  Tenant  shall furnish Landlord with:   (i) general contractor  and architect's  completion affidavits;
(i)full and final unconditional waivers of lien; (iii) receipted bills covering  all  labor  and  materials  expended and used; (iv) as-built plans of the Tenant Work; and (v) the certification of Tenant  and  its  architect that the Tenant Work has been constructed in a good and workmanlike manner in accordance with the Construction Documents,  and in accordance with applicable laws, codes and  ordinances.
(d)In no event shall Landlord be required to disburse the Building D Allowance more than one time per month. If the Tenant Work exceed the Building D Allowance, Tenant shall be entitled  to the  Building D Allowance in accordance with the terms hereof, but each individual  disbursement  of  the  Building D Allowance shall be disbursed in the proportion that the Building D Allowance bears to the total cost for the Tenant Work, less the ten percent (10%) retainage referenced above. Notwithstanding anything herein to the contrary, Landlord shall not be obligated to disburse any portion of the Building D Allowance during the continuance of an uncured default under the Lease,  and Landlord's  obligation to disburse  shall only resume when and if such default is  cured.

7.Unused Building D Allowance. Notwithstanding anything to the contrary set f01th herein, upon completion of the Tenant Work and application of the Building D Allowance to the costs related thereto pursuant to this Exhibit C, if any portion of the Building D Allowance is then remaining (the "Unused Building D Allowance"), Tenant shall be entitled to apply up to Seven and 50/100 Dollars ($7.50) per rentable square feet of the Building D Expansion Space (that is, up  to  $831,570.00)  of  such  Unused Building D Allowance  (if any) as follows:  (i) to the cost of purchasing  and installing Tenant's voice  and  data cabling and wiring at the Building D Expansion Space, (ii) to the cost of architectural services,  and (iii)  to the cost of moving expenses. If Tenant does not submit a request for payment of the entire Unused  Building D Allowance to Landlord in accordance with the provisions contained in this Exhibit  C  on  or before the expiration of twelve (12) months from the Building D Expansion Effective Date, any unused amount remaining after such date shall accrue to the sole benefit of Landlord, it  being understood  that  Tenant shall not be entitled to any credit, abatement or other concession  in  connection therewith.  Tenant  shall be responsible for all applicable state sales or use taxes, if any, payable in connection with the Tenant Work and/or Building D Allowance.

8.Landlord Oversight. Landlord would be entitled to an "Oversight  Fee" of  $70,000.00,  which shall be for providing the following services:
(a)Lead coordination between base building and tenant improvement  construction  teams;
		
	(b)
	Review and approve tenant improvement  plans;

		
	(c)
	Attend tenant improvement  construction meetings;

		
	(d)
	Review financials and qualifications  for tenant's proposed   contractors;

		
	(e)
	Review tenant improvement allowance payment applications including all required backup documentation to ensure that subcontractors have been paid and lien waivers  are in  place;

		
	(f)
	Review close-out packages and confirm that all as-built drawings as well as warranty documents are in place;

		
	(g)
	Review project scope of work to evaluate for restoration   requirements;

		
	(h)
	Review MEP drawings to ensure proposed  design does not adversely affect the  Building;

		
	(i)
	Review structural drawings to ensure proposed modifications or live loads don't adversely affect the Building;

		
	j)
	Coordinate  with  tenant  and  their  contractors  regarding  prope1ty  rules  and  regulations to ensure that contractors are not adversely impacting other tenants or normal Project operations;   and,

		
	(k)
	Monitor  Tenant's contactor  activities to ensure they  are not adversely  affecting the property outside the building.

Landlord and emergency personnel shall at all times have unfettered access to Building D in the event of 

an emergency.

9.Miscellaneous. Upon completion of the Landlord Work Tenant agrees to accept the Building D Expansion Space in its "as-is" condition and configuration, it being agreed that Landlord  shall  not  be required to perform any work or, except as provided above with respect to the Building D Allowance, incur any costs in connection with the construction or demolition of any improvements in the Building  D  Expansion Space.

II.     The Campus.
1.Tenant, following full and final execution and delivery of the Amendment to which this Exhibit C is attached and insurance certificates with respect to any contractors or vendors involved in the Tenant Work,  required  under  the  Lease,  as  amended  hereby,  shall  have  the  right  to  perform  all tenant improvements in any of the buildings composing The Campus (the "Campus Tenant Work"). Notwithstanding the foregoing, and unless expressly set fo1ih otherwise in this Section II specifically with respect to the Campus Tenant Work, Tenant's performance of the Campus Tenant Work shall comply with the terms and conditions set forth in Section I above, including A1iicle 9 of the Original Lease.

		
	2.
	Provided  Tenant is not  in default, Landlord  agrees to contribute the sum of $2,991,870.00 (that  is,

$15.00 per rentable square feet of The Campus) (the "Campus Allowance") toward the cost of performing the Campus Tenant Work. The Campus Allowance shall be utilized  during the period beginning on January  1, 2016, through and including May 1, 2019, provided, however, if Tenant does not submit a request for payment of the entire Campus Allowance to Landlord in accordance with the provisions contained in this Exhibit C, by May 1, 2019, any unused amount shall accrue to the sole benefit of Landlord, it being understood that Tenant shall not be entitled to any credit, abatement or other concession in connection therewith. In no event shall the Campus Allowance be used  for the purchase  of equipment,  furniture  or  other items of personal prope1iy of Tenant, soft costs, cabling expenses, moving expenses or applied against Base Rent and the terms of Section 1(8) shall not apply to the Campus   Allowance.

3.Prior to approving the final space plan for Tenant's work in The Campus and/or Building D  Expansion Space, Landlord shall identify po1iions of the applicable Tenant Work that Tenant shall  be required to remove from The Campus and/or Building D Expansion Space, as the case may be, at the expiration or earlier termination of the Lease, as amended  hereby.

4.At Tenant's discretion, Tenant may combine the Building D Allowance and the Campus Allowance for use on building improvement work within any of the Building D Expansion Space and/or The Campus. Notwithstanding the foregoing, such aggregation of Allowances shall only be available to  Tenant  if Landlord, in its reasonable judgment, determines that the Building D Expansion Space has been adequately and appropriately improved by the Building D Tenant Work. In addition, Landlord  shall be  entitled  to review and approve of all plans and specifications for all work performed  by Tenant at the  Project

		
	III.
	Miscellaneous.

1.Notwithstanding anything to the contrary set forth herein, provided that Tenant has provided to Landlord the documentation required for a disbursement of the Building D Allowance and/or the Campus Allowance (as applicable) hereunder (the "Required Disbursement Documentation and Tenant has fully pe1formed its obligations under this Exhibit C, (the "Disbursement Conditions, if (a) Tenant submits a request for disbursement of the Building D Allowance and/or the Campus Allowance (as applicable) on or before the date required in this Exhibit C and/or the Amendment,, and (b) Landlord fails to either pay the Building D Allowance and/or the Campus Allowance  (as  applicable)  (or the  applicable  p01iion  thereof) owed to Tenant or provide Tenant with written notice (which shall be delivered in accordance  with the  Notices provision of the Lease, as amended) of any Disbursement Condition that Tenant has failed to satisfy within ten (10) business days following Tenant's written request, Tenant shall have the right to  provide Landlord with a second request for disbursement, which second notice (which shall be delivered  in  accordance with the Notices provision of the Lease) must state substantially  the  following  in  bold  and capped font: "THIS IS TENANT'S SECOND REQUEST FOR  DISBURSEMENT  TO LANDLORD. LANDLORD FAILED TO DISBURSE THE [THE BUILDING D ALLOWANCE AND/OR THE CAMPUS ALLOWANCE (AS APPLICABLE)] TO TENANT IN ACCORDANCE WITH THE TERMS OF EXHIBIT C TO THE SEVENTH AMENDMENT. IF LANDLORD FAILS TO 

DISBURSE [THE BUILDING D ALLOWANCE AND/OR THE CAMPUS ALLOWANCE  (AS  APPLICABLE)]   OR  SPECIFY  IN  WRITING  WHICH  DISBURS

[2011-9599/00572913;8}                    C-6

CONDITIONS TENANT HAS FAILED TO SATISFY WITHIN TWENTY (20) DAYS FOLLOWING LANDLORD'S RECEIPT OF THIS NOTICE, TENANT SHALL HAVE THE RIGHT TO DEDUCT (UP TO TWENTY FIVE PERCENT (25%) OF THE AMOUNT OF BASE RENT PER MONTH UNTIL FULLY DISBURSED) THE PORTION OF THE TENANT IMPROVEMENT ALLOWANCE PAYABLE TO TENANT FROM THE NEXT INSTALLMENT
OF BASE RENT PAYABLE BY TENANT UNDER THE LEASE." If Tenant's second notice complies with the terms of this Section and Landlord's failure to respond continues for twenty (20) days after its receipt of such second request from Tenant, so long as the Disbursement Conditions have been fully satisfied, Tenant shall be entitled to deduct (up to twenty five percent (25%) of Base Rent per month until fully disbursed) the portion of the Building D Allowance and/or the Campus Allowance (as applicable) that is payable to Tenant hereunder from the next installment(s) of Base Rent due under the Lease, provided that Tenant shall endeavor to provide Landlord with reasonably detailed invoice of such amounts deducted from Base Rent hereunder prior to any such deduction.

Notwithstanding the foregoing, if within such twenty (20) day period Landlord provides written notice to Tenant specifying any conditions to disbursement of the Building D Allowance and/or the Campus Allowance (as applicable) that have not been satisfied by Tenant or if Landlord otherwise disputes that Tenant has fulfilled the requirements for the disbursement of the Building D Allowance and/or the Campus Allowance (as applicable), then Tenant shall not be entitled to deduct such amounts in dispute from Base Rent in accordance with this Section until such time as Tenant has satisfied such condition(s) to payment and, after providing the written notices set forth above, Landlord fails to pay the then-overdue Building D Allowance and/or the Campus Allowance (as applicable) disbursement within twenty (20) days thereafter.

2.This Exhibit C shall not be deemed applicable to any additional space added to the Building D Expansion Space at any time or from time to time, whether by any options under the Lease or otherwise, or to any portion of the original Building D Expansion Space or any additions to the Building D Expansion Space in the event of a renewal or extension of the original Term of the Lease, whether by any options under the Lease or otherwise, unless expressly so provided in the Lease or any amendment or supplement to the Lease.

[REMAINDER  OF PAGE INTENTIONALLY  LEFT BLANK]

{2011-9599/00572913;8}                    C-7

EXHIBIT D - LOCATION OF POTENTIAL EXTERIOR PERIMETER OF PARK

attached to and made a part of the Amendment dated as of November, 23,    015, between RAR2-CLEARVIEW  BUSINESS PARK OWNER, LLC, a Delaware limited liability company, as

Landlord, and GOPRO, INC., a Delaware corporation, as Tenant

(attachment not included due to HTML conversion issues)

{2011-9599/00572913;8}                    D-1Employment Agreement

This Employment Agreement is made and entered into effective January 11, 2016 (the "Effective Date"), by and among Los Alamos National Bank, a national banking association with its main office located in Los Alamos, New Mexico (the "Company"), and Joseph Martony ("Employee").  As used in this Agreement, capitalized terms have the meanings set forth in Section 21.

Recitals

A.            The Company is a wholly owned subsidiary of Trinity Capital Corporation, a New Mexico Corporation ("Trinity").

B.            The Company desires to employ Employee as Senior Risk Officer during the Initial Period, and, subject to regulatory approval, when the Employment Period commences, then as Chief Risk Officer.  Employee desires to be employed by the Company, on the terms and conditions set forth herein.

C.            The Parties have made commitments to each other on a variety of important issues concerning terms of employment, including the compensation Employee will be paid and his participation in both short-term, and long-term incentive programs.

D.            The Parties desire to enter into this Agreement as of the Effective Date and to have this Agreement supersede all agreements between the Parties, whether or not in writing, and to have any such prior agreements become null and void as of the Effective Date.

Agreement

In consideration of the foregoing and the mutual promises and covenants of the Parties set forth in this Agreement, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties, intending to be legally bound, hereby expressly covenant and agree as follows:

1.            Term.

(a)            Initial Period Engagement.  Employee is employed in an initial period position. The "Initial Period" of employment shall extend from the Effective Date of this Agreement and will terminate upon receipt of a determination by the Office of the Comptroller of the Currency (the "OCC") on the Interagency Biographical and Financial Report to be submitted by Employee pursuant to 12 U.S.C. 1831i. In the event that the Company receives a Notice of Disapproval from the OCC, then this Agreement shall terminate effective the date of the Notice of Disapproval, provided that Employee shall have had an opportunity to exhaust all measures to appeal for further consideration and any such appeal has been exhausted or the time to appeal has expired.

(b)            Employment Period.  Upon receipt by the Company of a favorable response from the OCC, with respect to the 12 U.S.C. 1831i application, then and thereafter Employee shall be given the title of Chief Risk Officer, an executive officer position with the Company.  The "Employment Period" shall commence on the date of receipt of the favorable response from the OCC and end on the second anniversary of the Effective Date, unless sooner terminated as provided herein, provided that the Employment Period shall be extended automatically for one additional year beginning on the second anniversary of the Effective Date and on each anniversary thereafter unless either Party notifies the other Party, by written notice delivered no later than 90 days prior to such anniversary, that the Employment Period shall not be extended.

(c)            At Will Employment.  At all times, Employee is employed as an "at will" employee and employment may be terminated by either party at any time without notice. Nothing in this agreement constitutes a guarantee of permanent or continued employment.

2.            Duties.

(a)            Employee shall devote Employee's full business time, energy, and talent to serving as Senior Risk Officer (and, as may be applicable, as Chief Risk Officer, an executive officer position with the Company), subject to the direction of the Chief Executive Officer.

(b)            Employee shall have the duties that are commensurate with Employee's positions and any other duties consistent therewith that may be assigned to Employee by the Chief Executive Officer, and Employee shall perform all such duties faithfully and efficiently.  Employee shall have such powers as are inherent to the undertakings applicable to Employee's positions and necessary to carry out the duties required of Employee hereunder.  During the Initial Period notwithstanding anything to the contrary, Employee shall not possess policy-making authority and shall not engage in policy-making activity without approval of the Company's Board.

(c)            Notwithstanding the foregoing provisions of this Section 2, Employee may devote reasonable time to activities other than those required under this Agreement, including activities of a charitable, educational, religious, or similar nature to the extent such activities do not, in the judgment of the Chief Executive Officer, inhibit, prohibit, interfere with, or conflict with Employee's duties under this Agreement or conflict in any material way with the business of the Company or any Affiliate; provided, however, that Employee shall not serve on the board of directors of any business or hold any other position with any business without receiving the prior written consent of the Chief Executive Officer.

3.            Compensation and Benefits.  While Employee is employed by the Company, he shall be compensated for his services as follows:

(a)            Employee shall be paid a base salary at an annual rate of $230,000.00 which shall be payable in accordance with the normal payroll practices of the Company then in effect.

(b)            Employee shall be eligible to receive performance-based annual bonuses (each, an "Incentive Bonus") at the sole discretion of the Company's Board, Trinity's Board and/or the Chief Executive Officer, or as may be set forth in an applicable incentive bonus plan, as may be in effect from time to time. Any Incentive Bonus shall be paid to Employee no later than two and one-half months after the close of the year in which it is earned, provided that any Incentive Bonus shall not be considered earned until the Board has made all determinations and taken all actions necessary to establish such Incentive Bonus.

(c)            Employee shall be eligible to participate, subject to the terms thereof, in all incentive plans of the Company as may be in effect from time to time with respect to executives of the Company, on as favorable a basis as other similarly situated and performing executives.

(d)            Employee and Employee's dependents, as the case may be, shall be eligible to participate, subject to the terms thereof, in all pension and similar benefit plans and all medical, dental, disability, group and life, accidental death and travel accident insurance, and other similar welfare benefit plans of the Company as may be in effect from time to time with respect to employees of the Company, on as favorable a basis as other similarly situated and performing employees.

(e)            Employee shall be entitled to accrue paid vacation days and holidays in accordance with and subject to the Company's paid time off programs and policies as may be in effect from time to time provided that Employee shall accrue a minimum of 20 vacation days and 10 sick days per calendar year.

(f)            If Employee relocates to the Los Alamos or Santa Fe, New Mexico area within 18 months of the Effective Date, the Company shall provide the following:

	
(i)

	
Reasonable costs for the moving and storage of household goods, temporary housing, interim travel, or closing costs (including sales commissions), subject to an aggregate cap of $20,000.  All such expenses must be submitted for reimbursement within 18 months of the Effective Date.

	
(ii)

	
Employee acknowledges and agrees to repay the Company any such relocation reimbursements, on a prorated basis, if Employee voluntarily resigns employment within the 24 month period immediately following the Effective Date.

	
(iii)

	
Any relocation assistance shall be included in Employee's IRS Form W-2 as wages and shall not be subject to any tax-gross up adjustments.

4.            Rights upon Termination.  This Agreement and Employee's employment under this Agreement may be terminated for any of the reasons described in this Section 4.  Employee's right to benefits, if any, for periods after the Termination Date shall be determined in accordance with this Section 4:

(a)            Minimum Benefits. If the Termination Date occurs during the Employment Period for any reason, Employee shall be entitled to the Minimum Benefits, in addition to any other benefits to which Employee may be entitled under the following provisions of this Section 4 or the express terms of any employee benefit plan or as required by law. Any benefits to be provided to Employee pursuant to this Section 4(a) shall be provided within 30 days after the Termination Date; provided, however, that any benefits, incentives, or awards payable as described in Section 4(e)(i) shall be provided in accordance with the terms of the applicable plan, program, or arrangement. Except as may expressly be provided to the contrary in this Agreement, nothing in this Agreement shall be construed as requiring Employee to be treated as employed by the Company or any Affiliate following the Termination Date for purposes of any plan, program, or arrangement.

(b)            Certain Terminations During the Employment Period.  If Employee's employment under this Agreement is terminated during the Employment Period as a result of (i) an Involuntary Termination, or (ii) Employee's voluntary Termination within 30 days following the effective date of the Change in Control, then, in addition to the Minimum Benefits, the Company shall pay to Employee in a single lump sum an amount equal to the Severance Amount, subject to all applicable tax withholding. The payment of the Severance Amount will be made by the Company on the 45th day following the Termination Date.  In addition to the foregoing, in the event of a termination under this section, Employee shall be entitled to receive a prorated Incentive Bonus for the year of termination based on the number of days employed during such year divided by 365, assuming target level performance through the date of termination.

(c)            Any Other Termination. If the Termination Date occurs during the Employment Period and is a result of any reason other than as set forth in Section 4(b) above, then, other than the Minimum Benefits, Employee shall have no right to benefits under this Agreement (and the Company and its Affiliates shall have no obligation to provide any such benefits) for periods after the Termination Date.

(d)            Golden Parachute Payment Adjustment. It is the intention of the Parties that no portion of any payment under this Agreement, or payments to or for the benefit of Employee under any other agreement or plan, be deemed to be an Excess Parachute Payment. The present value of payments to or for the benefit of Employee in the nature of compensation, receipt of which is contingent on a Change in Control, and to which Code Section 280G applies (in the aggregate "Total Payments") shall not exceed an amount equal to $1.00 less than the maximum amount that the Company may pay without loss of deduction under Code Section 280G(a). Present value for purposes of this Section 4(d) shall be calculated in accordance with Code Section 280G(d)(4). Within 90 days following the earlier of the giving of the notice of termination or the giving of notice by the Company to Employee of its belief that there is a payment or benefit due to Employee that will result in an Excess Parachute Payment, Employee and the Company, at the Company's expense, shall obtain the opinion of such legal counsel and certified public accountants as Employee may choose (notwithstanding the fact that such persons have acted or may also be acting as the legal counsel or certified public accountants for the Company), which opinions need not be unqualified, which set forth (i) the amount of the includable compensation of Employee for the base period, as determined under Code Section 280G, (ii) the present value of Total Payments, and (iii) the amount and present value of any Excess Parachute Payments. If such opinions determine that there would be an Excess Parachute Payment, the payment hereunder or any other payment determined by such counsel to be includable in Total Payments shall be modified, reduced, or eliminated as specified by Employee in writing delivered to the Company within 60 days of Employee's receipt of such opinions or, if Employee fails to so notify the Company, then as the Company shall reasonably determine, so that under the bases of calculation set forth in such opinions there will be no Excess Parachute Payment; provided, however, that any such specification by Employee or the Company shall not be effective where it would result in an imposition of any additional income tax under Code Section 409A. The provisions of this Section 4(d), including the calculations, notices, and opinions provided for herein shall be based upon the conclusive presumption that (A) the compensation provided for in this Agreement and (B) any other compensation earned by Employee pursuant to the Company's programs that would have been provided in any event are reasonable compensation for services rendered, even though the timing of such payment is triggered by the Change in Control; provided, however, that if such legal counsel so requests in connection with the opinion required by this Section 4(d), Employee and the Company shall obtain, at the Company's expense, and the legal counsel may rely on in providing the opinion, the advice of a firm of recognized executive compensation consultants as to the reasonableness of any item of compensation to be received by Employee.

(e)            Other Benefits.

	
(i)

	
Employee's rights following termination with respect to any benefits, incentives, or awards provided to Employee pursuant to the terms of any plan, program, or arrangement sponsored or maintained by the Company or its Affiliates, whether tax-qualified or not, which are not specifically addressed herein, shall be subject to the terms of such plan, program, or arrangement and this Agreement shall have no effect upon such terms except as specifically provided herein.

	
(ii)

	
Except as specifically provided herein and as pursuant to law, the Company and its Affiliates shall have no further obligations to Employee under this Agreement following termination.

(f)            Removal from any Boards and Positions. Unless otherwise agreed to in writing by the Parties at the time of Termination, upon a Termination, Employee shall be deemed to resign (i) if a member, from the Board and the board of directors of any Affiliate and any other board to which Employee has been appointed or nominated by or on behalf of the Company or an Affiliate, (ii) from each position with the Company and any Affiliate, including as an officer of the Company or an Affiliate and (iii) as a fiduciary of any employee benefit plan of the Company and any Affiliate.

(g)            Regulatory Suspension and Termination.

	
(i)

	
If Employee is suspended or temporarily prohibited from participating in the conduct of the affairs of the Company or an Affiliate by a notice served under Section 8(e) or 8(g) of the FDIA, all obligations of the Company and the Affiliates under this Agreement shall be suspended as of the date of service, unless stayed by appropriate proceedings, provided that if the charges in such notice are dismissed, the Company may in its discretion (A) pay Employee all or part of the compensation withheld while its and the Affiliates' obligations under this Agreement were suspended and (B) reinstate in whole or in part any of its and the Affiliates' obligations that were suspended, all in accordance with Code Section 409A.

	
(ii)

	
If Employee is removed or permanently prohibited from participating in the conduct of the affairs of the Company or an Affiliate by an order issued under Section 8(e) or 8(g) of the FDIA, all obligations of the Company and the Affiliates under this Agreement shall terminate as of the effective date of the order, provided that this Section 4 shall not affect any vested rights of the Parties.

	
(iii)

	
If the Company is in default as defined in Section 3(x) of the FDIA, all obligations of the Company under this Agreement shall terminate as of the date of default, provided that this Section 4 shall not affect any vested rights of the Parties.  Company represents and warrants that it is not under "Default" or "In Danger of Default" at the time of entering into this Agreement.

	
(iv)

	
All obligations of the Company under this Agreement shall be terminated, except to the extent determined by the FDIC that continuation of this Agreement is necessary for the continued operation of the institution, at the time the FDIC enters into an agreement to provide assistance to or on behalf of the Company under the authority contained in Section 13(c) of the FDIA, or when the Company is determined by the FDIC to be in an unsafe or unsound condition, provided that this Section 4 shall not affect any vested rights of the Parties. Provided however, Employee retains all rights to make such claims as may be permitted by the FDIC with respect to the termination of this Agreement at that time.

	
(v)

	
Any payments made to Employee pursuant to this Agreement, or otherwise, are subject to and conditioned upon their compliance with Section 18(k) of the FDIA.

(h)            Clawback.  Notwithstanding any provision of this Agreement to the contrary, Employee covenants and agrees that the Company and its successors and assigns shall have the right to demand the return of any "golden parachute payments" (as defined in 12 C.F.R. Part 359) in the event that information is obtained indicating that the Employee committed, is substantially responsible for, or has violated, the respective acts or omissions, conditions, or offenses contained in 12 C.F.R. § 359.4(a)(4) or any Severance Restriction applies.  Employee shall repay to the Company the aggregate amount of any such payments, with such repayment to occur no later than 30 days following Employee's receipt of a written notice from the Company indicating that payments received by Employee under this Agreement are subject to recapture or clawback pursuant to the Severance Restrictions and/or the terms of this paragraph.

5.            Release.  Notwithstanding any provision of this Agreement to the contrary, Employee shall not be entitled to any benefits under Section 4 (other than the Minimum Benefits), and shall repay to the Company any such benefits received, unless Employee executes (without subsequent revocation) and delivers to the Company a Release within 21 days (or such longer period to the extent required by applicable law) following the Termination Date.

6.            Restrictive Covenants.  Employee acknowledges that Employee has been and will continue to be provided intimate knowledge of the business practices, trade secrets, and other confidential and proprietary information of the Company (including the Confidential Information), which, if exploited by Employee, would seriously, adversely, and irreparably affect the interests of the Company and the ability of the Company to continue its business.  Employee further acknowledges that, during the course of Employee's employment with the Company, Employee may produce and have access to Confidential Information.

(a)            Confidential Information.  During the course of Employee's employment and following termination:

	
(i)

	
Employee shall not directly or indirectly use, disclose, copy, or make lists of Confidential Information for the benefit of anyone other than the Company, except to the extent that such information is or thereafter becomes lawfully available from public sources, or such disclosure is authorized in writing by the Company, required by law, or otherwise as reasonably necessary or appropriate in connection with the performance by Employee of Employee's duties to the Company.

	
(ii)

	
If Employee receives a subpoena or other court order or is otherwise required by law to provide information to a governmental authority or other person concerning the activities of the Company or its Affiliates, or Employee's activities in connection with the business of the Company or its Affiliates, Employee shall immediately notify the Company of such subpoena, court order, or other requirement and deliver forthwith to the Company a copy thereof and any attachments and non-privileged correspondence related thereto.

	
(iii)

	
Employee shall take reasonable precautions to protect against the inadvertent disclosure of Confidential Information.

	
(iv)

	
Employee shall abide by the Company's policies, as in effect from time to time, respecting avoidance of interests conflicting with those of the Company and its Affiliates.  In this regard, Employee shall not directly or indirectly render services to any person or entity where Employee's service would involve the use or disclosure of Confidential Information.

	
(v)

	
Employee shall not use any Confidential Information to guide Employee in searching publications or other publicly available information, selecting a series of items of knowledge from unconnected sources, and fitting them together to claim that Employee did not violate any terms set forth in this Agreement.

(b)            Documents and Property.

	
(i)

	
All records, files, documents, and other materials or copies thereof relating to the business of the Company or its Affiliates that Employee prepares, receives, or uses, shall be and remain the sole property of the Company and, other than in connection with the performance by Employee of Employee's duties to the Company, shall not be removed from the premises of the Company or its Affiliates without the Company's prior written consent, and shall be immediately returned to the Company upon termination, together with all copies (including copies or recordings in electronic form), abstracts, notes, or reproductions of any kind made from or about the records, files, documents, or other materials.

	
(ii)

	
Employee acknowledges that Employee's access to and permission to use the Company's and its Affiliates' computer systems, networks, and equipment, and all the Company and Affiliate information contained therein, is restricted to legitimate business purposes on behalf of the Company and reasonable personal use in accordance with the Company's applicable policies and procedures.  Any other access to or use of such systems, networks, equipment, and information is without authorization and is prohibited.  The restrictions contained in this Section 6 extend to any personal computers or other electronic devices of Employee that are used for business purposes relating to the Company or its Affiliates.  Employee shall not transfer any Company or Affiliate information to any personal computer or other electronic device that is not otherwise used for any business purpose relating to the Company or an Affiliate.  Upon termination, Employee's authorization to access and permission to use the Company's and its Affiliates' computer systems, networks, and equipment, and any Company and Affiliate information contained therein, shall cease, and Employee shall provide a copy of all such information to the Company and delete any Company and Affiliate information from Employee's personal computer or other electronic device.

(c)            Non-Competition and Non-Solicitation.  The primary service area of the Company's business in which Employee will actively participate extends separately to the Restricted Area.  Therefore, as an essential ingredient of and in consideration of this Agreement and Employee's employment with the Company, Employee shall not, during Employee's employment with the Company or during the Restricted Period, directly or indirectly do any of the following (all of which are collectively referred to in this Agreement as the "Restrictive Covenant"):

	
(i)

	
Engage or invest in, own, manage, operate, finance, control, participate in the ownership, management, operation, or control of, be employed by, associated with, or in any manner connected with, serve as a director, officer, or consultant to, lend Employee's name or any similar name to, lend Employee's credit to or render services or advice to, in each case in the capacity (or any substantially similar capacity) that Employee provided services to the Company, any person, firm, partnership, corporation, other business entity, or trust that owns, operates, or is in the process of forming a Competitor with an office located, or to be located at an address identified in a filing with any regulatory authority, within the Restricted Area; provided, however, that the ownership by Employee of shares of the capital stock of any institution, which shares are listed on a securities exchange and that do not represent more than 1% of the institution's outstanding capital stock, shall not violate any terms of this Agreement;

	
(ii)

	
Induce or attempt to induce any employee of the Company or its Affiliates to leave the employ of the Company or its Affiliates; (B) interfere with the relationship between the Company or its Affiliates and any employee of the Company or its Affiliates; or (C) induce or attempt to induce any customer, supplier, licensee, or other business relation of the Company or its Affiliates with whom Employee had an ongoing business relationship to cease doing business with the Company or its Affiliates or interfere with the relationship between the Company or its Affiliates and their respective customers, suppliers, licensees, or other business relations with whom Employee had an ongoing business relationship.

	
(iii)

	
Solicit the business of any person or entity known to Employee to be a customer of the Company or its Affiliates, where Employee, or any person reporting to Employee, had accessed Confidential Information of, had an ongoing business relationship with, or had made Substantial Business Efforts with respect to, such person or entity, with respect to products, activities, or services that compete in whole or in part with the products, activities, or services of the Company or its Affiliates.

	
(iv)

	
Serve as the agent, broker, or representative of, or otherwise assist, any person or entity in obtaining services or products from any Competitor within the Restricted Area, with respect to products, activities, or services that Employee devoted time to on behalf of the Company or any Affiliate (or any substantially similar products, activities, or services) and that compete in whole or in part with the products, activities, or services of the Company or its Affiliates.

	
(v)

	
Accept employment with, provide services to, or act in any other such capacity for or with any Competitor, if in such employment or capacity Employee would inevitably use or disclose the Company's Confidential Information in Employee's work or service for such Competitor.

(d)            Works Made for Hire; Ownership of Company Work Product.

	
(i)

	
The Parties understand and agree that all work prepared by Employee for the Company or for its Affiliates shall be a Work Made For Hire as such phrase is defined under the U.S. Copyright laws, 17 U.S.C. § 101 et seq., and if such work does not qualify as a Work Made For Hire, Employee shall, and does, assign to the Company all of Employee's right, title, and interest in and to the work, including all patent, copyright, trademark, and other proprietary rights thereto.  Employee waives and releases all moral rights in any of the works as Employee may possess by virtue of the Visual Artist's Moral Rights Act of 1990 and various country or state laws of attribution, authorship, and integrity commonly referred to as Moral Rights Law.  Employee shall not assert any claim based upon such moral rights against the Company, the Affiliates, or any of their respective successors in interest or assigns.  Employee shall have no right, title, or interest in any of the work and shall not be entitled to any royalties or other proceeds received by the Company or its Affiliates from the commercialization in any manner of the work.

	
(ii)

	
Employee hereby assigns to the Company any right, title, and interest in and to all Company Work Product that Employee may have, by law or equity, without additional consideration of any kind whatsoever from the Company or its Affiliates.

	
(iii)

	
Employee shall execute and deliver any instruments or documents and do all further acts (including the giving of testimony and executing any applications, oaths, and assignments) requested by the Company (both before and after a Termination) in order to vest more fully in the Company or its Affiliates all ownership rights in the Company Work Product (including obtaining patent, copyright, trademark, or other intellectual property protection therefore in the United States and foreign countries). 

	
(iv)

	
The Company or its Affiliates shall at all times own and have exclusive right, title, and interest in and to all Confidential Information and Company Work Product, and the Company or its Affiliates shall retain the exclusive right to use, license, sell, transfer, and otherwise exploit and dispose of the same.  Employee acknowledges the Company's or its Affiliates' exclusive right, title, and interest in and to the Confidential Information and Company Work Product, and shall not contest, challenge or make any claim adverse to the Company's or its Affiliates' ownership of or the validity of the Confidential Information and Company Work Product, any future application for registration or registration thereof, or any rights of the Company or its Affiliates therein, or which, directly or indirectly, may impair any part of the Company's or its Affiliates' right, title, and interest therein.

	
(v)

	
To the extent required by applicable state statute, this Section 6(d) shall not apply to an invention for which no equipment, supplies, facility, or trade secret information of the Company or its Affiliates was used and that was developed entirely on Employee's own time, unless the invention (i) relates to the business of the Company or an Affiliate or to the Company's or an Affiliate's actual or demonstrably anticipated research or development or (ii) results from any work performed by Employee for the Company or an Affiliate. 

(e)            Consent and Release.  From time to time, the Company's locations may be the subject of a Promotional Work.  Employee acknowledges that Employee is aware that Employee's name, image, and likeness may be captured in such Promotional Work, and hereby consents and agrees that the Company may use Employee's name, image, and likeness as captured in the Promotional Work in any manner, in connection with the Company's products and services, and, at all times, the Company, its Affiliates, and, without limitation, their respective customers, successors, licensees, and assigns, may continue to use the Promotional Work that includes Employee's name, image, or likeness.  Employee, Employee's heirs, predecessors, successors, assigns, and all affiliated entities hereby fully and finally release, remise, and forever discharge the Company, its Affiliates, their respective predecessors, successors, assigns, and all affiliated entities, and each of their respective directors, officers, members, shareholders, partners, employees, customers, agents, and attorneys, to the extent that such apply, of and from any and all manner of actions, causes of action, losses, claims, demands, liabilities, obligations, suits, debts, sums of money, accounts, reckonings, bonds, bills, specialties, covenants, controversies, agreements, promises, variances, trespasses, damages, judgments, and executions, in law or in equity, that arise out of or are related to the Company's or its Affiliates' use of a Promotional Work that includes Employee's name, image, or likeness.

(f)            Online Medium.

	
(i)

	
Employee shall not create or otherwise establish any Online Medium without the Company's prior written consent.  Notwithstanding the foregoing, if Employee creates Online Medium without such prior written consent, Employee shall, and hereby does (A) assign to the Company any right, title, and interest Employee may have in and to the Online Medium and (B) transfer to the Company all primary administrative rights to the Online Medium, including all codes and passwords.  If the Company has approved the content of any material to be posted or otherwise used online and obtained primary administrative rights to the Online Medium, then the Company may, at its sole and absolute discretion, provide Employee with subordinate administrative access to, and guidelines for, Employee's use of such Online Medium in connection with Employee's duties under this Agreement.  Employee has no right, title, or interest to any material or other information on any Online Medium including all "fans," "followers," "friends," and "contacts" associated therewith that mentions, uses, or refers in any way to Company Proprietary and Intellectual Property, Company Work Product, or Confidential Information, which shall remain the sole and exclusive property of the Company, even if such Online Medium is established by Employee or otherwise held in the name of Employee.  Upon a Termination, the Company will remove Employee's administrative access to the Online Medium. 

	
(ii)

	
Employee shall execute and deliver any instruments or documents and do all further acts (including the giving of testimony and executing any applications, oaths, and assignments) requested by the Company (both before and after a Termination) in order to vest more fully in the Company or its Affiliates all ownership rights in the Online Medium (including obtaining any available intellectual property or similar protection therefore in the United States and foreign countries).

	
(iii)

	
The Company or its Affiliates shall at all times own and have exclusive right, title, and interest in and to all Online Medium, and the Company or its Affiliates shall retain the exclusive right to use, license, sell, transfer, and otherwise exploit and dispose of the same.  Employee acknowledges the Company's or its Affiliates' exclusive right, title, and interest in and to the Online Medium, and shall not contest, challenge, or make any claim adverse to the Company's or its Affiliates' ownership of or the validity of the Online Medium, any future application for registration or registration thereof, or any rights of the Company or its Affiliates therein, or which, directly or indirectly, may impair any part of the Company's or its Affiliates' right, title, and interest therein.

(g)            Company Proprietary and Intellectual Property.  The Company or its Affiliates shall at all times own and have exclusive right, title, and interest in and to all Company Proprietary and Intellectual Property, and the Company or its Affiliates shall retain the exclusive right to use, license, sell, transfer, and otherwise exploit and dispose of the same.  Employee acknowledges the Company's or its Affiliates' exclusive right, title, and interest in and to Company Proprietary and Intellectual Property, and shall not contest, challenge, or make any claim adverse to the Company's or its Affiliates' ownership of or the validity of Company Proprietary and Intellectual Property, any future application for registration or registration thereof, or any rights of the Company or its Affiliates therein, or which, directly or indirectly, may impair any part of the Company's or its Affiliates' right, title, and interest therein.  Employee shall not use or otherwise exploit any of Company Proprietary and Intellectual Property in any manner not authorized by the Company.

(h)            Remedies for Breach of Restrictive Covenant.

	
(i)

	
Employee has reviewed the provisions of this Agreement with legal counsel, or has been given adequate opportunity to seek such counsel, and Employee acknowledges that the covenants contained in this Section 6 are reasonable with respect to their duration and scope.

	
(ii)

	
Employee acknowledges that (A) the restrictions contained in this Section 6 are reasonable and necessary for the protection of the legitimate business interests of the Company, (B) such restrictions create no undue hardships, (C) any violation of these restrictions would seriously, adversely, and irreparably injure the Company and such interests, and (D) such restrictions were a material inducement to the Company to employ Employee and to enter into this Agreement.  Provided however, any business process or concepts that are standard industry or emerging practices throughout the industry shall not be within the scope of these restrictions.

	
(iii)

	
Employee must, and the Company may, communicate the existence of this Agreement and only the sections of this Agreement related to the Restrictive Covenants to any third party with whom Employee may seek or obtain future employment or other similar arrangement during the Restricted Period.

	
(iv)

	
In the event of any violation or threatened violation of the restrictions contained in this Section 6, the Company, in addition to and not in limitation of, any other rights, remedies, or damages available to the Company under this Agreement or otherwise at law or in equity, shall not be required to provide any amounts or benefits under this Agreement and shall be entitled to preliminary and permanent injunctive relief to prevent or restrain any such violation by Employee and all persons directly or indirectly acting for or with Employee, as the case may be, without any requirement that the Company post bond.

	
(v)

	
If Employee violates the Restrictive Covenant and the Company brings legal action for injunctive or other relief, the Company shall not, as a result of the time involved in obtaining such relief, be deprived of the benefit of the full period of the Restrictive Covenant; accordingly, the Restrictive Covenant shall be deemed to have the duration specified herein computed from the date the relief is granted but reduced by the time between the period when the Restricted Period began to run and the date of the first violation of the Restrictive Covenant by Employee.

(i)            Other Agreements.  In the event of the existence of another agreement between the Parties that (i) is in effect during the Restricted Period, and (ii) contains restrictive covenants that conflict with any of the provisions of this Section 6, then the more restrictive of such provisions from the two agreements shall control for the period during which both agreements would otherwise be in effect.

7.            Notices.  Notices and all other communications under this Agreement shall be in writing and shall be deemed given when mailed by United States registered or certified mail, return receipt requested, postage prepaid, addressed as follows: if to the Company, to the principal headquarters of the Company, attention: General Counsel; and if to Employee, to Employee's most recent address in the Company's records; or, in each respective case, to such other address as either Party may furnish to the other in writing, except that notices of changes of address shall be effective only upon receipt.

8.            Governing Law.  This Agreement shall be governed by and construed under the laws of the State of New Mexico, without regard to principles of conflict of laws (whether in the State of New Mexico or any other jurisdiction) that would cause the application of the laws of any jurisdiction other than the State of New Mexico.

9.            Choice of Venue and Consent to Jurisdiction.  Each Party hereby irrevocably submits to the exclusive jurisdiction of the First Judicial District Court for the State of New Mexico, if such courts have or can acquire jurisdiction, and if such jurisdiction does not exist and cannot be acquired, to the exclusive jurisdiction of the United States District Court for the District of New Mexico, for the purpose of any suit, action, or other proceeding arising out of or based on this Agreement or any other agreement contemplated hereby or any subject matter hereof, whether in tort, contract, or otherwise.

10.            Service of Process.  Each Party may be served with process in any manner permitted under State of New Mexico law, or by United States registered or certified mail, return receipt requested.

11.            Entire Agreement.  This Agreement  constitutes the entire agreement between the Parties concerning the subject matter hereof, and supersedes all prior negotiations, undertakings, agreements, and arrangements with respect thereto, whether written or oral, including any written offer of employment.

12.            Withholding of Taxes.  The Company may withhold from any benefits payable under this Agreement all federal, state, city and other taxes as may be required pursuant to any law, governmental regulation, or ruling.

13.            No Assignment.  Employee's right to receive benefits under this Agreement shall not be assignable or transferable whether by pledge, creation of a security interest, or otherwise, other than a transfer by will or by the laws of descent or distribution.  In the event of any attempted assignment or transfer contrary to this Section 13, the Company and its Affiliates shall have no liability to pay any amount so attempted to be assigned or transferred.  This Agreement shall inure to the benefit of and be enforceable by Employee's personal and legal representatives, executors, administrators, successors, heirs, distributees, devisees, and legatees.

14.            Successors.  This Agreement shall be binding upon and inure to the benefit of the Company, its successors, and assigns.

15.            Legal Fees.  In the event that either Party commences mediation, arbitration, litigation, or any similar action to enforce or protect such Party's rights in accordance with and under this Agreement, the prevailing Party in any such action shall be entitled to recover reasonable attorneys' fees and costs (including the costs of experts, evidence, and counsel) and other costs relating to such action, in addition to all other entitled relief, including damages and injunctive relief.

16.            Amendment.  This Agreement may not be amended or modified except by written agreement signed by the Parties.

17.            Acknowledgement.  Employee hereby represents that from and after the Effective Date the performance of Employee's duties hereunder will not breach any other agreement to which Employee is a party.  Employee acknowledges that Employee has read and understands this Agreement, is fully aware of its legal effect, has not acted in reliance upon any representations or promises made by the Company other than those contained in writing herein, and has entered into this Agreement freely based on Employee's own judgment.

18.            No Inconsistent Obligations. Employee represents and warrants that he is aware of no obligations legal or otherwise that are inconsistent with the terms of this Agreement or with his employment by the Company. Employee will not disclose to the Company, or use, or induce the Company to use, any proprietary information or trade secrets of others. Employee represents and warrants that he has returned all proprietary and confidential information belonging to all prior employers. Employee represents and warrants that his employment under this Agreement will not, directly or indirectly, cause or result in a violation of any restrictive covenants contained in any agreements with any prior employers. Employee will not disclose to the Company, or use, or induce the Company to use, any proprietary information or trade secrets of others. Employee represents and warrants that he has returned all proprietary and confidential information belonging to all prior employers.

19.            Code Section 409A.

(a)            To the extent any provision of this Agreement or action by the Company would subject Employee to liability for interest or additional taxes under Code Section 409A, it shall be deemed null and void, to the extent permitted by law and deemed advisable by the Company.  It is intended that this Agreement will comply with Code Section 409A, and this Agreement shall be administered accordingly and interpreted and construed on a basis consistent with such intent.  Notwithstanding any provision of this Agreement to the contrary, no termination or similar payments or benefits shall be payable hereunder on account of a Termination unless such Termination constitutes a "separation from service" within the meaning of Code Section 409A.  For purposes of Code Section 409A, all installment payments of deferred compensation made hereunder, or pursuant to another plan or arrangement, shall be deemed to be separate payments.  To the extent any reimbursements or in-kind benefit payments under this Agreement are subject to Code Section 409A, such reimbursements and in-kind benefit payments shall be made in accordance with Treasury Regulation Section 1.409A-3(i)(1)(iv).  This Agreement may be amended to the extent necessary (including retroactively) by the Company to avoid the application of taxes or interest under Code Section 409A, while maintaining to the maximum extent practicable the original intent of this Agreement.  This Section 19 shall not be construed as a guarantee of any particular tax effect for Employee's benefits under this Agreement and the Company does not guarantee that any such benefits will satisfy the provisions of Code Section 409A or any other provision of the Code.

(b)            Notwithstanding any provision of this Agreement to the contrary, if Employee is determined to be a Specified Employee as of the date of termination, then, to the extent required pursuant to Code Section 409A, payments due under this Agreement that are deemed to be deferred compensation shall be subject to a six-month delay following the Termination Date; and all delayed payments shall be accumulated and paid in a lump-sum payment as of the first day of the seventh month following the date of termination (or, if earlier, as of Employee's death), with all such delayed payments being credited with interest (compounded monthly) for this period of delay equal to the prime rate in effect on the first day of such six-month period.  Any portion of the benefits hereunder that were not otherwise due to be paid during the six-month period following the date of termination shall be paid to Employee in accordance with the payment schedule established herein.

20.            Construction.

(a)            In this Agreement, unless otherwise stated, the following uses apply: (i) references to a statute refer to the statute and any amendments and any successor statutes, and to all regulations promulgated under or implementing the statute, as amended, or its successors, as in effect at the relevant time; (ii) in computing periods from a specified date to a later specified date, the words "from" and "commencing on" (and the like) mean "from and including," and the words "to," "until," and "ending on" (and the like) mean "to, and including"; (iii) references to a governmental or quasi-governmental agency, authority, or instrumentality also refer to a regulatory body that succeeds to the functions of the agency, authority, or instrumentality; (iv) indications of time of day are based upon the time applicable to the location of the principal headquarters of the Company; (v) the words "include," "includes," and "including" (and the like) mean "include, without limitation," "includes, without limitation," and "including, without limitation," (and the like) respectively; (vi) all references to preambles, recitals, sections, and exhibits are to preambles, recitals, sections, and exhibits in or to this Agreement; (vii) the words "hereof," "herein," "hereto," "hereby," "hereunder," (and the like) refer to this Agreement as a whole (including exhibits); (viii) any reference to a document or set of documents, and the rights and obligations of the parties under any such documents, means such document or documents as amended from time to time, and all modifications, extensions, renewals, substitutions, or replacements thereof; (ix) all words used shall be construed to be of such gender or number as the circumstances and context require; (x) the captions and headings of preambles, recitals, sections, and exhibits appearing in or attached to this Agreement have been inserted solely for convenience of reference and shall not be considered a part of this Agreement, nor shall any of them affect the meaning or interpretation of this Agreement or any of its provisions; and (xi) all accounting terms not specifically defined herein shall be construed in accordance with GAAP.

(b)            If a court of competent jurisdiction determines that any provision of this Agreement is invalid or unenforceable, then the invalidity or unenforceability of that provision shall not affect the validity or enforceability of any other provision of this Agreement and all other provisions shall remain in full force and effect.

(c)            The various covenants and provisions of this Agreement are intended to be severable and to constitute independent and distinct binding obligations.

(d)            Without limiting the generality of the foregoing, if the scope of any covenant contained in this Agreement is too broad to permit enforcement to its full extent, such covenant shall be enforced to the maximum extent permitted by law, and such scope may be judicially modified accordingly.

(e)            This Agreement may be executed in any number of counterparts, each of which shall be deemed an original, and all of which together shall constitute one and the same Agreement.

21.            Definitions.  As used in this Agreement, the terms defined in this Section 21 have the meanings set forth below.

(a)            "1934 Act" means the Securities Exchange Act of 1934.

(b)            "Affiliate" means each Business Entity that, directly or indirectly, is controlled by, controls, or is under common control with, the Company, where "control" means (i) the ownership of more than 50% of the Voting Securities or other voting or equity interests of any Business Entity, or (ii) the possession, directly or indirectly, of the power to direct or cause the direction of the management and policies of such Business Entity.

(c)            "Agreement" means this employment agreement, made and entered into as of the Effective Date, by and between the Parties.

(d)            "Annual Base Salary" has the meaning set forth in Section 3(a).

(e)            "Business Entity" means any corporation, partnership, limited liability company, joint venture, association, partnership, business trust or other business entity.

(f)            "Change in Control" means the first to occur of the following:

	
(i)

	
The consummation of the acquisition by any "person" (as such term is defined in Section 13(d) or 14(d) of the 1934 Act) of "beneficial ownership" (within the meaning of Rule 13d-3 promulgated under the 1934 Act) of more than 50% of the combined voting power of the then outstanding Voting Securities of Trinity;

	
(ii)

	
During any 12-month period, the individuals who, as of the Effective Date, are members of the Trinity Board cease for any reason to constitute a majority of the Board, unless the election, or nomination for election by Trinity shareholders, of any new director was approved by a vote of a majority of the Board, in which case such new director shall, for purposes of this Agreement, be considered as a member of the Trinity Board; or

	
(iii)

	
The consummation by Trinity of: (A) a merger or consolidation if Trinity's shareholders immediately before such merger or consolidation do not, as a result of such merger or consolidation, own, directly or indirectly, more than 50% of the combined voting power of the then outstanding Voting Securities of the entity resulting from such merger or consolidation in substantially the same proportion as their ownership of the combined voting power of the Voting Securities of Trinity outstanding immediately before such merger or consolidation; or (B) a complete liquidation or dissolution of, or an agreement for the sale or other disposition of all or substantially all of the assets of, Trinity.

Notwithstanding any provision of this definition to the contrary, a Change in Control shall not be deemed to have occurred solely because more than 50% of the combined voting power of the then outstanding securities of Trinity are acquired by (A) a trustee or other fiduciary holding securities under one or more employee benefit plans maintained by Trinity or an Affiliate or (B) any corporation that, immediately prior to such acquisition, is owned directly or indirectly by Trinity's shareholders in the same proportion as their ownership of stock immediately prior to such acquisition.

Further notwithstanding any provision of this definition to the contrary, in the event that any amount or benefit under this Agreement constitutes deferred compensation under Code Section 409A and the settlement of or distribution of such amount or benefit is to be triggered by a Change in Control, then such settlement or distribution shall be subject to the event constituting the Change in Control also constituting a "change in control event" under Code Section 409A.

(g)            "Company" means Los Alamos National Bank, a national chartered bank with its main office located in Los Alamos, New Mexico.

(h)            "Company's Board" means the Board of Directors of the Company.

(i)            "Code" means the Internal Revenue Code of 1986.

(j)            "Company Proprietary and Intellectual Property" means all products, systems, methods, procedures, techniques, manuals, databases, plans, lists, inventions, discoveries, innovations, improvements, enhancements, concepts, ideas, and software conceived, created, compiled, or otherwise developed by the Company or its Affiliates and/or comprised, in whole or part, of Confidential Information, together with all patent rights, copyrights, trademarks, service marks, trade name rights and other source identifiers, trade secrets, and other intellectual property and property rights therein, if any.

(k)            "Company Work Product" means all products, systems, methods, procedures, techniques, manuals, databases, plans, lists, inventions, discoveries, innovations, improvements, enhancements, concepts, ideas, and software conceived, created, compiled, or otherwise developed by Employee in the course of Employee's employment with the Company or its Affiliates and/or comprised, in whole or part, of Confidential Information, together with all patent rights, copyrights, trademarks, service marks, trade name rights, trade secrets, and other intellectual property and propriety rights therein, if any.  Notwithstanding the foregoing sentence, to the extent required by applicable state statute, Company Work Product shall not include (i) any inventions independently developed by Employee and not derived, in whole or part, from any Confidential Information or (ii) any invention made by Employee prior to Employee's exposure to any Confidential Information.

(l)            "Competitor" means a bank, savings bank, savings and loan association, credit union, or similar financial institution.

(m)            "Confidential Information" means confidential or proprietary non-public information concerning the Company or its Affiliates, including research, development, designs, formulae, processes, specifications, technologies, marketing materials, financial and other information concerning customers and prospective customers, customer lists, records, data, computer programs, source codes, object codes, database structures, trade secrets, proprietary business information, pricing and profitability information, policies, strategic planning, commitments, plans, procedures, litigation, pending litigation, and other information not generally available to the public.

(n)            "Effective Date" means January 11, 2016.

(o)            "Employment Period" has the meaning set forth in Section 1.

(p)            "Excess Parachute Payment" has the meaning set forth in Code Section 280G.

(q)            "Employee" means Joseph Martony.

(r)            "FDIA" means the Federal Deposit Insurance Act.

(s)            "FDIC" means the Federal Deposit Insurance Corporation.

(t)            "Good Reason" means the occurrence of any one of the following events, unless Employee agrees in writing that such event shall not constitute Good Reason:

	
(i)

	
A material and adverse change in the nature, scope, or status of Employee's position, authorities, or duties from those in effect in accordance with Section 2; provided, however, that a change in title as a result of a merger or reorganization of the Company, where Employee maintains a similar level of responsibility or oversight (including, where applicable, duties with respect to a public company officer or director), shall not constitute Good Reason or a breach of this Agreement;

	
(ii)

	
A material reduction in Employee's then-current Annual Base Salary, or a material reduction in Employee's Incentive Bonus opportunity, aggregate benefits or other compensation plans in effect immediately following the Effective Date;

	
(iii)

	
A relocation of Employee's primary place of employment of more than 50 miles, which relocation also causes Employee's primary place of employment to be located further from Employee's primary residence; or

	
(iv)

	
A material breach by the Company of this Agreement.

Notwithstanding any provision of this Good Reason definition to the contrary, (A) prior to a Termination for Good Reason, Employee must give the Company written notice of the existence of any condition set forth in a clause immediately above within 90 days of its initial existence and the Company shall have 30 days from the date of such notice in which to cure the condition giving rise to Good Reason, if curable, and if, during such 30-day period, the Company cures the condition giving rise to Good Reason, such condition shall not constitute Good Reason and (B) any Termination for Good Reason must occur within six months of the initial existence of the condition constituting Good Reason.

(u)            "Involuntary Termination" means a Termination during the Employment Period either:

	
(i)

	
By the Company, its Affiliates or successors, other than a Termination for Cause; or

	
(ii)

	
By Employee for Good Reason.

(v)            "Minimum Benefits" means, as applicable, the following:

	
(i)

	
Employee's earned but unpaid Annual Base Salary for the period ending on the date of termination;

	
(ii)

	
Employee's earned but unpaid bonus, if any, for any completed fiscal year preceding the date of termination; provided, however, that Employee shall not be entitled to any bonus in the event of a Termination for Cause;

	
(iii)

	
Employee's accrued but unpaid vacation pay for the period ending on the date of termination; and

	
(iv)

	
Employee's unreimbursed business expenses through and including the date of termination, provided that all required submissions for expense reimbursement are made in accordance with the Company's expense reimbursement policy and within 15 days following the date of termination.

(w)            "Online Medium" means any website, domain, social network account or identity, blog, feed, email address, email distribution list, or other Internet account or presence (including Instagram, Tumblr, Facebook, Twitter, and Flicker) that incorporates, exploits, utilizes, displays, or otherwise makes use of any of the Company Proprietary and Intellectual Property, Company Work Product, or Confidential Information.

(x)            "Parties" means the Company and Employee.

(y)            "Promotional Work" means, without limitation, photographs, films, clips, sketches, segments, and other media and promotional works.

(z)            "Release" means a general release and waiver substantially in the form attached hereto as Exhibit A.

(aa)            "Restricted Area" means the area that encompasses a 35-mile radius from each banking or other office location of the Company and its Affiliates.

(bb)            "Restricted Period" means a period of 18 months immediately following a Termination, whether such Termination occurs during the Employment Period or thereafter.

(cc)            "Restrictive Covenant" has the meaning set forth in Section 6.

(dd)            "Severance Amount" means an amount equal to 100% of Employee's Annual Base Salary as of the respective Termination.

(ee)            "Severance Restrictions" means any applicable statute, law, regulation, or regulatory interpretation or other guidance, including FIL-66-2010 and any related or successor FDIC guidance, that would require the Company or any Affiliate to seek or demand repayment or return of any payments made to Employee for any reason, including the Company, an Affiliate or their successors later obtaining information indicating that Employee has committed, is substantially responsible for, or has violated, the respective acts or omissions, conditions, or offenses outlined under 12 C.F.R. 359.4(a)(4). Additionally, the obligation to make payment of the Severance Amount as provided herein is conditioned upon (i) the Company obtaining any necessary approvals from each of their primary federal regulators (including, where applicable, FDIC concurrence), and (ii) compliance with applicable law, including 12 C.F.R. Part 359.

(ff)            "Specified Employee" means any person who is a "key employee" (as defined in Code Section 416(i) without regard to paragraph (5) thereof), as determined by the Company based upon the 12-month period ending on each December 31st (such 12-month period is referred to below as the "identification period").  If Employee is determined to be a key employee, Employee shall be treated as a Specified Employee for purposes of this Agreement during the 12-month period that begins on the April 1 following the close of the identification period.  For purposes of determining whether Employee is a key employee, "compensation" means Employee's W-2 compensation as reported by the Company for a particular calendar year.

(gg)            "Substantial Business Efforts" means marketing, promotional, purchasing, sales, or solicitation activities undertaken on behalf of the Company or an Affiliate, which include (i) in person and voice communications and (ii) either or both of (A) delivery of a quote, bid, proposal, or request for any of the foregoing or (B) visits to the site of the actual or potential business development and other similar meetings or visits (conducted alone or with other employees of the Company or an Affiliate), where such activities would enjoy a reasonable prospect of success in the absence of any breach of this Agreement.

(hh)            "Termination" means termination of Employee's employment with the Company and all Affiliates for any reason or no reason.

(ii)            "Termination Date" means the date of Termination.

(jj)            "Termination for Cause" means a termination of Employee's employment by the Company as a result of any of the following (in each case as determined by the Company Board:

	
(i)

	
Employee's willful and continuing failure to perform Employee's obligations hereunder, which failure is not remedied within 10 business days after receipt of written notice of such failure from the Company;

	
(ii)

	
Employee's conviction of, or plea of nolo contendere to, a crime of embezzlement or fraud or any felony under the laws of the United States or any state thereof;

	
(iii)

	
Employee's breach of fiduciary responsibility;

	
(iv)

	
An act of dishonesty by Employee that is materially injurious to the Company or an Affiliate;

	
(v)

	
Employee's engagement in one or more unsafe or unsound banking practices that have a material adverse effect on the Company or an Affiliate;

	
(vi)

	
Employee's removal or permanent suspension from banking pursuant to Section 8(e) of the FDIA or any other applicable state or federal law;

	
(vii)

	
A material breach by Employee of this Agreement;

	
(viii)

	
An act or omission by Employee that leads to a material harm (financial or reputational) to the Company or an Affiliate; or

	
(ix)

	
A material breach by Employee of Company policies as may be in effect from time to time.

Further, a Termination for Cause shall be deemed to have occurred if, within 12 months following the Termination, facts and circumstances arising during the course of such employment are discovered that would have warranted a Termination for Cause.

Further, with respect to subsections (i), (vii), (viii), and (ix), Employee shall be entitled to at least 30 days' prior written notice of the Company's intention to terminate Employee's employment in a Termination for Cause, which notice shall specify the grounds for the Termination for Cause; and Employee shall be provided a reasonable opportunity to cure any conduct or act, if curable, alleged as grounds for the Termination for Cause, and a reasonable opportunity to present to the Company Board Employee's position regarding any dispute relating to the existence of any grounds for Termination for Cause.

Further, all rights Employee has or may have under this Agreement shall be suspended automatically during (A) the pendency of any investigation by the Company Board or its designee, or (B) any negotiations between the Company Board or its designee and Employee regarding any actual or alleged act or omission by Employee of the type that would warrant a Termination for Cause and any such suspension shall not give rise to a claim of Good Reason by Employee.

(kk)            "Total Payments" has the meaning set forth in Section 4(d).

(ll)            "Trinity" means Trinity Capital Corporation.

(mm)            "Voting Securities" means any securities that ordinarily possess the power to vote in the election of directors without the happening of any precondition or contingency.

22.            Survival.  The provisions of Section 6 shall survive the termination of this Agreement.

[The remainder of this page intentionally left blank.]

IN WITNESS WHEREOF, the Company has caused this Agreement to be executed in its name and on its behalf, and Employee acknowledges understanding and acceptance of, and agrees to, the terms of this Agreement, all as of the Effective Date.

LOS ALAMOS NATIONAL BANK

By:               /s/ John S. Gulas                                                                                                 

John S. Gulas

Chief Executive Officer

Joseph Martony

By:             /s/ Joseph Martony                                                                                                   

EXHIBIT A

Agreement and Release and Waiver

This Agreement and Release ("Agreement") is made and entered into by and between Los Alamos National Bank (the "Company") and [_______________] ("Employee").

Whereas, Employee and the Company desire to settle fully and amicably all issues between them, including any issues arising out of Employee's employment with the Company and the termination of that employment; and

Whereas, Employee and the Company are parties to that certain Employment Agreement, made and entered into as of [_______________], as amended (the "Employment Agreement").

Now, therefore, for and in consideration of the mutual promises contained herein, and for other good and sufficient consideration, receipt of which is hereby acknowledged, Employee and the Company (collectively, the "Parties" and, individually, each a "Party"), intending to be legally bound, hereby agree as follows:

1.            Termination of Employment.  Employee's employment with the Company shall terminate effective as of the close of business on [_______________] (the "Termination Date").

2.            Compensation and Benefits.  Subject to the terms of this Agreement, the Company shall compensate Employee under this Agreement as follows (collectively, the "Severance Payments"):

(a)            Severance Amount.  [_______________].

(b)            Accrued Salary and Vacation.  Employee shall be entitled to a lump sum payment in an amount equal to Employee's earned but unpaid annual base salary and vacation pay for the period ending on the Termination Date, with such payment to be made on the first payroll date following the Termination Date.

(c)            Employee Acknowledgement.  Employee acknowledges that, subject to fulfillment of all obligations provided for herein, Employee has been fully compensated by the Company, including under all applicable laws, and that nothing further is owed to Employee with respect to wages, bonuses, severance, other compensation, or benefits.  Employee further acknowledges that the Severance Payments (other than (b) above) are consideration for Employee's promises contained in this Agreement, and that the Severance Payments are above and beyond any wages, bonuses, severance, other compensation, or benefits to which Employee is entitled from the Company under the terms of Employee's employment or under any other contract or law that Employee would be entitled to absent execution of this Agreement.

(d)            Withholding.  The Severance Payments shall be treated as wages and subject to all taxes and other payroll deductions required by law.

3.            Termination of Benefits.  Except as provided in Section 2 above or as may be required by law, Employee's participation in all employee benefit (pension and welfare) and compensation plans of the Company shall cease as of the Termination Date.  Nothing contained herein shall limit or otherwise impair Employee's right to receive pension or similar benefit payments that are vested as of the Termination Date under any applicable tax-qualified pension or other plans, pursuant to the terms of the applicable plan.

4.            Release of Claims and Waiver of Rights.  Employee, on Employee's own behalf and that of Employee's heirs, executors, attorneys, administrators, successors, and assigns, fully releases and discharges the Company, its predecessors, successors, parents, subsidiaries, affiliates, and assigns, and its and their directors, officers, trustees, employees, and agents, both in their individual and official capacities, and the current and former trustees and administrators of each retirement and other benefit plan applicable to the employees and former employees of the Company, both in their official and individual capacities (the "Releasees") from all liability, claims, demands, and actions Employee now has, may have had, or may ever have, whether currently known or unknown, as of or prior to Employee's execution of this Agreement (the "Release"), including liability claims, demands, and actions:

(a)            Arising from or relating to Employee's employment or other association with the Company, or the termination of such employment,

(b)            Relating to wages, bonuses, other compensation, or benefits,

(c)            Relating to any employment or change in control contract,

(d)            Relating to any employment law, including

	
(i)

	
The United States and State of New Mexico Constitutions,

	
(ii)

	
The Civil Rights Act of 1964,

	
(iii)

	
The Civil Rights Act of 1991,

	
(iv)

	
The Equal Pay Act,

	
(v)

	
The Employee Retirement Income Security Act of 1974,

	
(vi)

	
The Age Discrimination in Employment Act (the "ADEA"),

	
(vii)

	
The Americans with Disabilities Act,

	
(viii)

	
Executive Order 11246, and

	
(ix)

	
Any other federal, state, or local statute, ordinance, or regulation relating to employment,

(e)            Relating to any right of payment for disability,

(f)            Relating to any statutory or contractual right of payment, and

(g)            For relief on the basis of any alleged tort or breach of contract under the common law of the State of New Mexico or any other state, including defamation, intentional or negligent infliction of emotional distress, breach of the covenant of good faith and fair dealing, promissory estoppel, and negligence.

Employee acknowledges that Employee is aware that statutes exist that render null and void releases and discharges of any claims, rights, demands, liabilities, actions, and causes of action that are unknown to the releasing or discharging party at the time of execution of the release and discharge.  Employee waives, surrenders, and shall forego any protection to which Employee would otherwise be entitled by virtue of the existence of any such statutes in any jurisdiction, including the State of New Mexico.

5.            Exclusions from General Release.  Excluded from the Release are any claims or rights that cannot be waived by law, as well as Employee's right to file a charge with an administrative agency or participate in any agency investigation.  Employee is, however, waiving the right to recover any money in connection with a charge or investigation.  Employee is also waiving the right to recover any money in connection with a charge filed by any other individual or by the Equal Employment Opportunity Commission or any other federal or state agency.

6.            Covenant Not to Sue.

(a)            A "covenant not to sue" is a legal term that means Employee promises not to file a lawsuit in court.  It is different from the release of claims and waiver of rights contained in Section 4 above.  Besides waiving and releasing the claims covered by Section 4 above, Employee shall never sue the Releasees in any forum for any reason covered by the Release.  Notwithstanding this covenant not to sue, Employee may bring a claim against the Company to enforce this Agreement, to challenge the validity of this Agreement under the ADEA or for any claim that arises after execution of this Agreement.  If Employee sues any of the Releasees in violation of this Agreement, Employee shall be liable to them for their reasonable attorneys' fees and costs (including the costs of experts, evidence, and counsel) and other litigation costs incurred in defending against Employee's suit.  In addition, if Employee sues any of the Releasees in violation of this Agreement, the Company can require Employee to return all but a sum of $100 of the Severance Payments, which sum is, by itself, adequate consideration for the promises and covenants in this Agreement.  In that event, the Company shall have no obligation to make any further Severance Payments.

(b)            If Employee has previously filed any lawsuit against any of the Releasees, Employee shall immediately take all necessary steps and execute all necessary documents to withdraw or dismiss such lawsuit to the extent Employee's agreement to withdraw, dismiss, or not file a lawsuit would not be a violation of any applicable law or regulation.

7.            Representations by Employee.  Employee warrants that Employee is legally competent to execute this Agreement and that Employee has not relied on any statements or explanations made by the Company or its attorneys.  Employee acknowledges that Employee has been afforded the opportunity to be advised by legal counsel regarding the terms of this Agreement, including the Release.  Employee acknowledges that Employee has been offered at least 21 days to consider this Agreement.  After being so advised, and without coercion of any kind, Employee freely, knowingly, and voluntarily enters into this Agreement.  Employee acknowledges that Employee may revoke this Agreement within seven days after Employee has signed this Agreement and acknowledges understanding that this Agreement shall not become effective or enforceable until seven days after Employee has signed this Agreement (the "Effective Date"), as evidenced by the date set forth below Employee's signature on the signature page hereto.  Any revocation must be in writing and directed to [_______________].  If sent by mail, any revocation must be postmarked within the seven-day period described above and sent by certified mail, return receipt requested.

8.            Restrictive Covenants.  Section 6 of the Employment Agreement (entitled "Restrictive Covenants"), shall continue in full force and effect as if fully restated herein.

9.            Non-Disparagement.  Employee shall not engage in any disparagement or vilification of the Releasees, and shall refrain from making any false, negative, critical, or disparaging statements, implied or expressed, concerning the Releasees, including regarding management style, methods of doing business, the quality of products and services, role in the community, or treatment of employees.  Employee shall do nothing that would damage the Company's business reputation or goodwill.

10.            Company Property.

(a)            Employee shall return to the Company all information, property, and supplies belonging to the Company or any of its affiliates, including any confidential or proprietary information, Company autos, keys (for equipment or facilities), laptop computers and related equipment, cellular phones, smart phones or PDAs (including SIM cards), security cards, corporate credit cards, and the originals and all copies of all files, materials, and documents (whether in tangible or electronic form) containing confidential or proprietary information or relating to the business of the Company or any of its affiliates.

(b)            Employee shall not, at any time on or after the Termination Date, directly or indirectly use, access, or in any way alter or modify any of the databases, e-mail systems, software, computer systems, or hardware or other electronic, computerized, or technological systems of the Company or any of its affiliates.  Employee acknowledges that any such conduct by Employee would be illegal and would subject Employee to legal action by the Company, including claims for damages and/or appropriate injunctive relief.

11.            No Admissions.  The Company denies that the Company or any of its affiliates, or any of their employees or agents, has taken any improper action against Employee, and this Agreement shall not be admissible in any proceeding as evidence of improper action by the Company or any of its affiliates or any of their employees or agents.

12.            Confidentiality of Agreement.  Employee shall keep the existence and the terms of this Agreement confidential, except for Employee's immediate family members and Employee's legal and tax advisors in connection with services related hereto and except as may be required by law or in connection with the preparation of tax returns.

13.            Non-Waiver.  The Company's waiver of a breach of this Agreement by Employee shall not be construed or operate as a waiver of any subsequent breach by Employee of the same or of any other provision of this Agreement.

14.            Governing Law.  This Agreement shall be governed by and construed under the laws of the State of New Mexico, without regard to principles of conflict of laws (whether in the State of New Mexico or any other jurisdiction) that would cause the application of the laws of any jurisdiction other than the State of New Mexico.

15.            Legal Fees.  In the event that either Party commences mediation, arbitration, litigation, or any similar action to enforce or protect such Party's rights in accordance with and under this Agreement, the prevailing Party in any such action shall be entitled to recover reasonable attorneys' fees and costs (including the costs of experts, evidence, and counsel) and other costs relating to such action, in addition to all other entitled relief, including damages and injunctive relief.

16.            Entire Agreement.  This Agreement sets forth the entire agreement of the Parties regarding the subject matter hereof, and shall be final and binding as to all claims that have been or could have been advanced on behalf of Employee pursuant to any claim arising out of or related in any way to Employee's employment with the Company and the termination of that employment.

17.            Counterparts.  This Agreement may be executed in any number of counterparts, each of which shall be deemed an original, but all of which together shall constitute one and the same Agreement.

18.            Successors.  This Agreement shall be binding upon and inure to the benefit of the Company, its successors and assigns.

19.            Enforcement.  The provisions of this Agreement shall be regarded as divisible and separable and if any provision should be declared invalid or unenforceable by a court of competent jurisdiction, the validity and enforceability of the remaining provisions shall not be affected thereby.  If the scope of any restriction or requirement contained in this Agreement is too broad to permit enforcement of such restriction or requirement to its full extent, then such restriction or requirement shall be enforced to the maximum extent permitted by law, and Employee hereby consents that any court of competent jurisdiction may so modify such scope in any proceeding brought to enforce such restriction or requirement.  In addition, Employee stipulates that breach by Employee of restrictions and requirements under this Agreement will cause irreparable damage to the Releasees in the case of Employee's breach and that the Company would not have entered into this Agreement without Employee binding Employee to these restrictions and requirements.  In the event of Employee's breach of this Agreement, in addition to any other remedies the Company may have, and without bond and without prejudice to any other rights and remedies that the Company may have for Employee's breach of this Agreement, the Company shall be relieved of any obligation to provide Severance Payments and shall be entitled to an injunction to prevent or restrain any such violation by Employee and all persons directly or indirectly acting for or with Employee.  Employee stipulates that the restrictive period for which the Company is entitled to an injunction shall be extended in for a period that equals the time period during which Employee is or has been in violation of the restrictions contained herein.

20.            Construction.  In this Agreement, unless otherwise stated, the following uses apply: (a) references to a statute refer to the statute and any amendments and any successor statutes, and to all regulations promulgated under or implementing the statute, as amended, or its successors, as in effect at the relevant time; (b) in computing periods from a specified date to a later specified date, the words "from" and "commencing on" (and the like) mean "from and including, " and the words "to," "until," and "ending on" (and the like) mean "to, and including"; (c) references to a governmental or quasi-governmental agency, authority, or instrumentality also refer to a regulatory body that succeeds to the functions of the agency, authority, or instrumentality; (d) indications of time of day are based upon the time applicable to the location of the principal headquarters of the Company; (e) the words "include," "includes," and "including" (and the like) mean "include, without limitation," "includes, without limitation," and "including, without limitation," (and the like) respectively; (f) all references to preambles, recitals, sections, and exhibits are to preambles, recitals, sections, and exhibits in or to this Agreement; (g) the words "hereof," "herein," "hereto," "hereby," "hereunder," (and the like) refer to this Agreement as a whole (including exhibits); (h) any reference to a document or set of documents, and the rights and obligations of the parties under any such documents, means such document or documents as amended from time to time, and all modifications, extensions, renewals, substitutions, or replacements thereof; (i) all words used shall be construed to be of such gender or number as the circumstances and context require; (j) the captions and headings of preambles, recitals, sections, and exhibits appearing in or attached to this Agreement have been inserted solely for convenience of reference and shall not be considered a part of this Agreement, nor shall any of them affect the meaning or interpretation of this Agreement or any of its provisions; and (k) all accounting terms not specifically defined herein shall be construed in accordance with GAAP.

21.            Future Cooperation.  In connection with any and all claims, disputes, negotiations, governmental, internal or other investigations, lawsuits, or administrative proceedings (the "Legal Matters") involving the Company or any affiliate, or any of their current or former officers, employees or board members (collectively, the "Disputing Parties" and, individually, each a "Disputing Party"), Employee shall make himself reasonably available, upon reasonable notice from the Company and without the necessity of subpoena, to provide information and documents, provide declarations and statements regarding a Disputing Party, meet with attorneys and other representatives of a Disputing Party, prepare for and give depositions and testimony, and otherwise cooperate in the investigation, defense, and prosecution of any and all such Legal Matters, as may, in the good faith and judgment of the Company, be reasonably requested.  The Company shall consult with Employee and make reasonable efforts to schedule such assistance so as not to materially disrupt Employee's business and personal affairs.  The Company shall reimburse all reasonable expenses incurred by Employee in connection with such assistance, including travel, meals, rental car, and hotel expenses, if any; provided such expenses are approved in advance by the Company and are documented in a manner consistent with expense reporting policies of the Company as may be in effect from time to time.

In witness whereof, the Parties have duly executed this Agreement as of the dates set forth below their respective signatures below.

LOS ALAMOS NATIONAL BANK

By:                                                                                                                  

Print Name                                                                                                                

Title:                                                                                                                

Date:                                                                                                                

[EMPLOYEE]

By:                                                                                                                  

Print Name                                                                                                                

Title:                                                                                                                

Date:

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00255-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00255-of-00352.parquet"}]]