Document:

EX-10.29

 Exhibit 10.29 

EXECUTION COPY 
 AGREEMENT OF
LEASE 
 between 
 RFL 160 FIFTH
LLC, 
 Landlord 
 and 

FORRESTER RESEARCH, INC., 
 Tenant

 Dated: April 30, 2010 

160 Fifth Avenue 
 New York, New
York 

 TABLE OF CONTENTS 
  

							
	 	 	 	  	Page	 
			
	ARTICLE 1	 	 GLOSSARY
	  	 	2	  
	ARTICLE 2	 	 DEMISE, PREMISES, TERM, RENT
	  	 	8	  
	ARTICLE 3	 	 ESCALATION
	  	 	9	  
	ARTICLE 4	 	 ELECTRICITY
	  	 	18	  
	ARTICLE 5	 	 USE AND OCCUPANCY
	  	 	20	  
	ARTICLE 6	 	 ALTERATIONS
	  	 	21	  
	ARTICLE 7	 	 REPAIRS; FLOOR LOAD
	  	 	25	  
	ARTICLE 8	 	 WINDOW CLEANING
	  	 	26	  
	ARTICLE 9	 	 REQUIREMENTS OF LAW
	  	 	27	  
	ARTICLE 10	 	 SUBORDINATION
	  	 	29	  
	ARTICLE 11	 	 RULES AND REGULATIONS
	  	 	33	  
	ARTICLE 12	 	 INSURANCE, PROPERTY LOSS OR DAMAGE; REIMBURSEMENT
	  	 	33	  
	ARTICLE 13	 	 DESTRUCTION BY FIRE OR OTHER CAUSE
	  	 	36	  
	ARTICLE 14	 	 EMINENT DOMAIN
	  	 	39	  
	ARTICLE 15	 	 ASSIGNMENT, SUBLETTING, MORTGAGE, ETC.
	  	 	40	  
	ARTICLE 16	 	 ACCESS TO PREMISES
	  	 	47	  
	ARTICLE 17	 	 CERTIFICATE OF OCCUPANCY
	  	 	49	  
	ARTICLE 18	 	 DEFAULT
	  	 	49	  
	ARTICLE 19	 	 REMEDIES AND DAMAGES
	  	 	51	  
	ARTICLE 20	 	 FEES AND EXPENSES
	  	 	53	  
	ARTICLE 21	 	 NO REPRESENTATIONS BY LANDLORD
	  	 	54	  
	ARTICLE 22	 	 END OF TERM
	  	 	54	  
	ARTICLE 23	 	 POSSESSION
	  	 	55	  
	ARTICLE 24	 	 NO WAIVER
	  	 	57	  
	ARTICLE 25	 	 WAIVER OF TRIAL BY JURY
	  	 	57	  
	ARTICLE 26	 	 INABILITY TO PERFORM
	  	 	58	  
	ARTICLE 27	 	 BILLS AND NOTICES
	  	 	59	  
	ARTICLE 28	 	 SERVICES AND EQUIPMENT
	  	 	60	  
	ARTICLE 29	 	 PARTNERSHIP TENANT
	  	 	65	  
	ARTICLE 30	 	 VAULT SPACE
	  	 	65	  
	ARTICLE 31	 	 SIGNS
	  	 	66	  
	ARTICLE 32	 	 BROKER
	  	 	66	  
	ARTICLE 33	 	 INDEMNITY
	  	 	66	  
	ARTICLE 34	 	 ADJACENT EXCAVATION; SHORING
	  	 	68	  
	ARTICLE 35	 	 OPTION TO CANCEL
	  	 	68	  
	ARTICLE 36	 	 RENT REGULATION
	  	 	69	  
	ARTICLE 37	 	 COVENANT OF QUIET ENJOYMENT
	  	 	69	  
	ARTICLE 38	 	 ICIP PROGRAM
	  	 	69	  
	ARTICLE 39	 	 MISCELLANEOUS
	  	 	70	  
	ARTICLE 40	 	 SECURITY DEPOSIT
	  	 	76	  
	ARTICLE 41	 	 ROOF INSTALLATIONS
	  	 	78	  
	ARTICLE 42	 	 OPTION TO RENEW
	  	 	79	  
	ARTICLE 43	 	 RIGHT OF FIRST OFFER
	  	 	81	  
	ARTICLE 44	 	 USE OF ROOF
	  	 	83	  
	ARTICLE 45	 	 SELF-HELP
	  	 	83	  

  
 i 

 TABLE OF CONTENTS 
  

 

					
	 	 	 	  	Page
			
	SCHEDULE A	 	 Floor Plan
	  	
	SCHEDULE B	 	 Building Rules and Building Standards for Alterations
	  	
	SCHEDULE C	 	 Work Agreement
	  	
	SCHEDULE C-1	 	 Layout Plan
	  	
	SCHEDULE D	 	 Cleaning Services
	  	
	SCHEDULE E	 	 Form of Letter of Credit
	  	
	SCHEDULE F	 	 Rules and Regulations
	  	
	SCHEDULE G	 	 Form of Non-Disturbance Agreement
	  	
	SCHEDULE H	 	 Commencement Date Agreement
	  	
	SCHEDULE I	 	 Building Holidays
	  	
	SCHEDULE J	 	 Pre-Existing Rights
	  	
	SCHEDULE K	 	 Temporary Certificate of Occupancy
	  	

  
 ii 

 AGREEMENT OF LEASE, made as of the 30th day of April 2010 between RFL 160 FIFTH LLC, a Delaware
limited liability company, having an address at c/o RFR Holding LLC, 390 Park Avenue, 3rd Floor, New York, New York 10022, (“Landlord”) and FORRESTER RESEARCH, INC., a Delaware corporation, having an address at 400 Technology
Square, Cambridge, Massachusetts 02139 (“Tenant”). 
 REFERENCE PAGE 

In addition to other terms elsewhere defined in this Lease, the following terms whenever used in this Lease shall have the meanings set forth
in this Reference Page. 
  

					
	(1)	 	Premises:	 	The entire third (3rd) floor of the Building, as approximately shown on the floor plan annexed to this Lease as Schedule A. Landlord and Tenant conclusively agree that for
all purposes of this Lease, (i) the Premises consist of 15,219 rentable square feet, and (ii) the Building contains 122,328 rentable square feet.
			
	(2)	 	Commencement Date:	 	The date that is the earlier to occur of (a) the Substantial Completion Date and (b) the date Tenant (or any person claiming by, through or under Tenant) occupies any portion of the Premises for the conduct of its business;
provided, however, that in no event shall the Commencement Date occur prior to August 15, 2010.
			
	(3)	 	Rent Commencement Date:	 	The date that is one hundred thirty-eight (138) days after the Commencement Date.
			
	(4)	 	Fixed Expiration Date:	 	The last day of the month in which the day immediately preceding the tenth (10th) anniversary of the Rent Commencement Date shall occur.
			
	(5)	 	Term:	 	Approximately ten (10) years and one hundred thirty-eight (138) days from the Commencement Date to the Fixed Expiration Date, subject to Tenant’s right to renew the Term under Article 42 and Tenant’s right to
cancel this Lease under Article 35.
			
	(6)	 	Fixed Rent:	 	$837,045 per annum ($69,753.75 per month) from the Rent Commencement Date through the Fixed Expiration Date.
			
	(7)	 	Tenant’s Share:	 	12.44%.

					
			
	(8)	 	Base Tax Factor:	 	The Taxes payable for the Tax Year commencing on July 1, 2011, taking into account any exemption or abatement in effect pursuant to the ICIP.
			
	(9)	 	Base Operating Factor:	 	The Operating Expenses paid or incurred with respect to the Operating Year beginning January 1, 2010.
			
	(10)	 	Permitted Use:	 	The Premises shall be used for general, administrative and executive offices and uses incidentally and directly related thereto.
			
	(11)	 	Broker(s):	 	Cushman and Wakefield, Inc., Richards Barry Joyce & Partners, Studley, Inc. and RFR Realty LLC.
			
	(12)	 	Late Charge:	 	As more particularly set forth in Section 20.2, and subject to the terms thereof, (i) three percent (3%) of any Rental not paid within five (5) days after becoming due and (ii) interest at the Applicable Rate on any Rental
not paid within ten (10) days after becoming due, computed from the date such Rental was due (without regard to such grace period) through the date paid.
			
	(13)	 	Tenant Improvement Allowance:	 	$989,235.
			
	(14)	 	Security Deposit:	 	$279,015.00 (subject to reduction as set forth in Section 40.6).
			
	(15)	 	Renewal Term:	 	One (1) term of five (5) years.
			
	(16)	 	Option to Cancel:	 	As described in Article 35.

 W I T N E S S E T H: 

The parties hereto, for themselves, their legal representatives, successors and assigns, hereby agree as follows: 

ARTICLE 1 
 GLOSSARY 

The following terms shall have the meanings indicated below: 

“AAA” shall have the meaning set forth in Section 42.3. 

  
 2 

 “ADA” shall have the meaning set forth in Section 9.1. 

“Additional Rent” shall have the meaning set forth in Section 2.2. 

“Administrative Code” shall mean the Administrative Code of the City of New York, as amended. 

“Alteration Fee” shall have the meaning set forth in Section 6.2. 

“Alterations” shall mean alterations, decorations, installations, repairs, improvements, additions, replacements or other
physical changes in or about the Premises made by Tenant. 
 “Applicable Rate” shall mean the lesser of (x) three
percentage points above the then current Base Rate, and (y) the maximum rate permitted by applicable law. 
 “ASHRAE”
shall mean the American Society of Heating, Refrigeration and Air-Conditioning Engineers. 
 “Bankruptcy Code” shall mean
11 U.S.C. Section 101 et seq., or any statute, federal or state, of similar nature and purpose. 
 “Baseball
Arbitrator” shall have the meaning set forth in Section 42.3. 
 “Base Rate” shall mean the rate of
interest publicly announced from time to time by Citibank, N.A., or its successor, as its “base rate” (or such other term as may be used by Citibank, N.A., from time to time, for the rate presently referred to as its “base
rate”). 
 “BID Charges” shall have the meaning set forth in Section 3.1. 

“Building” shall mean the buildings, equipment and other improvements and appurtenances of every kind and description now
located or hereafter erected, constructed or placed upon the Land and any and all alterations, renewals, and replacements thereof, additions thereto and substitutions therefor. 

“Building Systems” shall mean the base building mechanical, electrical, sanitary, heating, air conditioning, ventilating,
elevator, plumbing, life-safety and other service systems of the Building, but shall not include installations made by Tenant or fixtures or appliances. 

“Business Days” shall mean all days, excluding Saturdays, Sundays and all days then observed as holidays by the State of New
York, the federal government or the labor unions servicing the Building. As of the date of this Lease, the holidays observed by the Building are as set forth on Schedule I annexed hereto. 

“Cancellation Notice” shall have the meaning set forth in Article 35. 

“Cancellation Option Termination Date” shall have the meaning set forth in Article 35. 

“Cancellation Payment” shall have the meaning set forth in Article 35. 

  
 3 

 “Class E Systems” shall mean the fire and life safety system of the Building and
its components. 
 “Control” shall have the meaning set forth in Section 15.3. 

“Critical Services” shall have the meaning set forth in Section 28.3(B). 

“Decorative Alterations” shall have the meaning set forth in Section 6.1. 

“Deficiency” shall have the meaning set forth in Section 19.2. 

“DOF” shall have the meaning set forth in Section 38.1. 

“DSBS” shall have the meaning set forth in Section 38.1. 

“DX Maintenance Obligations” shall have the meaning set forth in Section 45.1. 

“DX Unit” shall have the meaning set forth in Section 28.1(C). 

“Electricity Additional Rent” shall have the meaning set forth in Section 4.2. 

“Escalation Rent” shall mean payments required to be made by Tenant pursuant to Article 3. 

“Event of Default” shall have the meaning set forth in Section 18.1. 

“Existing Mortgagee” shall mean Union Labor Life Insurance Company. 

“Expiration Date” shall mean the Fixed Expiration Date or such earlier or later date on which the Term sooner or later ends
pursuant to any of the terms, conditions or covenants of this Lease or pursuant to law. 
 “Fair Market Value” shall mean
the rental rate determined at the applicable times set forth in this Lease (i) with respect to the Renewal Term or (ii) with respect to ROFO Space, for vacant space pursuant to a direct lease that a willing landlord would accept and a
willing tenant would pay in buildings of comparable age and quality of the Building located in the immediate vicinity of the Building and taking into account all relevant factors, whether favorable to Landlord or Tenant, including, without
limitation, tenant improvement allowances, rental concessions, abatements and brokerage commissions being offered or paid by landlords of buildings of comparable age and quality of the Building located in the immediate vicinity of the Building. 

“Government Authority (Authorities)” shall mean the United States of America, the State of New York, the City of New York,
any political subdivision thereof and any agency, department, commission, board, bureau or instrumentality of any of the foregoing, now existing or hereafter created, having jurisdiction over the Real Property or any portion thereof. 

“HVAC” shall mean heat, ventilation and air conditioning. 

  
 4 

 “HVAC System” shall mean the Building Systems providing HVAC, including the DX
Unit described in Section 28.1(C) of this Lease. 
 “Hazardous Materials” shall have the meaning set forth in
Section 9.2. 
 “ICIP” shall have the meaning set forth in Section 38.1. 

“Indemnitees” shall mean Landlord, its trustees, partners, shareholders, officers, directors, employees, agents and
contractors and the Manager (and the partners, shareholders, officers, directors and employees of Landlord’s agents and contractors and of the Manager). 

“Installations” shall have the meaning set forth in Section 41.1. 

“Issuer” shall have the meaning set forth in Section 40.2. 

“Issuer Criteria” shall have the meaning set forth in Section 40.2. 

“Land” shall mean the land known by the address of 160 Fifth Avenue, New York, New York. 

“Landlord” on the date as of which this Lease is made, shall mean RFL 160 Fifth LLC, a Delaware limited liability company,
but thereafter, “Landlord” shall mean only the fee owner of the Real Property or, if there then exists a Superior Lease, the tenant thereunder. 

“Landlord’s Maximum Determination” shall have the meaning set forth in Section 42.2. 

“Landlord’s Operating Statement” shall mean a good faith statement containing a computation of Escalation Rent due
pursuant to the provisions of Section 3.3 furnished by Landlord to Tenant. 
 “Landlord’s Statement” shall
mean either a Landlord’s Operating Statement or a Landlord’s Tax Statement. 
 “Landlord’s Tax Statement”
shall mean a good faith statement containing a computation of Escalation Rent due pursuant to the provisions of Section 3.2 furnished by Landlord to Tenant. 

“Landlord’s Work” shall have the meaning set forth in Schedule C annexed. 

“Laws” shall mean all present and future laws, rules, ordinances, regulations, statutes, requirements, codes and executive
orders, extraordinary as well as ordinary, retroactive and prospective, of all Government Authorities now existing or hereafter created, and of any applicable fire rating bureau, or other body exercising similar functions, affecting the Real
Property, or any street, avenue or sidewalk comprising a part or in front thereof or any vault in or under the same, or requiring removal of any encroachment, or affecting the maintenance, use or occupation of the Real Property. 

“Lessor(s)” shall mean a lessor under a Superior Lease. 

“Letter of Credit” shall have the meaning set forth in Section 40.2. 

  
 5 

 “Manager” shall mean RFR Realty LLC, or any successor contractor under
Landlord’s contract for the management of the Building. 
 “Mortgage(s)” shall mean any mortgage which may now or
hereafter affect the Real Property, the Building or any Superior Lease and the leasehold interest created thereby, and all renewals, extensions, supplements, amendments, modifications, consolidations and replacements thereof or thereto,
substitutions therefor, and advances made thereunder. 
 “Mortgagee(s)” shall mean any trustee under or mortgagee or holder
of a Mortgage. 
 “Non-Disturbance Agreement” shall have the meaning set forth in Section 10.7. 

“Non-Renewal Notice” shall have the meaning set forth in Section 40.2. 

“Notice(s)” shall have the meaning set forth in Section 27.1. 

“Operating Expenses” shall have the meaning set forth in Section 3.1. 

“Operating Hours” shall mean 8:00 a.m. to 6:00 p.m. on Business Days. 

“Operating Year” shall mean each calendar year that includes any part of the Term. 

“Overtime Periods” shall have the meaning set forth in Section 28.2. 

“Parties” shall have the meaning set forth in Section 39.2. 

“Partnership Tenant” shall have the meaning set forth in Article 29. 

“Person(s) or person(s)” shall mean any natural person or persons, a partnership, a corporation and any other form of
business or legal association or entity. 
 “Persons Within Landlord’s Control” shall mean and include Landlord,
Manager and all of their respective principals, officers, agents, contractors, servants, employees and licensees 
 “Persons Within
Tenant’s Control” shall mean and include Tenant, all of Tenant’s respective principals, officers, agents, contractors, servants, employees, licensees and invitees. 

“Real Property” shall mean the Building and the Land. 

“Recapture Space” shall have the meaning set forth in Section 15.4. 

“Recapture Sublease” shall have the meaning set forth in Section 15.4. 

“Recapture Subtenant” shall have the meaning set forth in Section 15.4. 

“Renewal Notice” shall have the meaning set forth in Section 42.1. 

“Renewal Option” shall have the meaning set forth in Section 42.1. 

  
 6 

 “Rental” shall mean and be deemed to include Fixed Rent, Additional Rent and any
other sums payable by Tenant hereunder. 
 “Requirements” shall mean (i) all Laws, (ii) all requirements,
obligations and conditions of all instruments of record on the date of this Lease, and (iii) all requirements, obligations and conditions imposed by the carrier of Landlord’s hazard insurance policy for the Building. 

“Rules and Regulations” shall mean the rules and regulations annexed hereto as Schedule F, and such other reasonable
modifications and additions to same as Landlord and Landlord’s agents may from time to time adopt, on reasonable advance written notice to Tenant to be given in accordance with the terms of this Lease. The parties agree that rules and
regulations which are designed for the safety or security of occupants of the Building, property in the Building or the Building itself shall be deemed to be reasonable, including without limitation, rules requiring tenants to cause their mail to be
opened outside the Building and irradiated or otherwise cleaned before being brought into the Building when external circumstances justify such action. Landlord shall not discriminate against Tenant in enforcing the Rules and Regulations. 

“Specialty Installations” shall have the meaning set forth in Section 6.1(C). 

“Sublease Additional Rent” shall have the meaning set forth in Section 15.5. 

“Sublease or Assignment Statement” shall have the meaning set forth in Section 15.4. 

“Substantially Completed” or “Substantial Completion” shall, whenever used in this Lease with respect to
work to be performed by Landlord, be deemed to mean that stage of the progress of such work as shall enable Tenant to have (a) the services to be provided to Tenant pursuant to Article 28 hereof, and (b) access to the Premises to
commence Tenant’s use and occupancy of the Premises without unreasonable interference by reason of the need to complete unfinished details of work (and, if applicable, adjustment of equipment and fixtures) to be performed by Landlord. Within
twenty (20) days after work performed by Landlord shall have been Substantially Completed, Tenant shall deliver to Landlord a punchlist of items of unfinished work required by this Lease to be performed by Landlord (“Tenant’s
Punchlist”). Landlord shall diligently complete the unfinished items of work identified in Tenant’s Punchlist. 

“Substantial Completion Date” shall mean the date on which Landlord’s Work is Substantially Completed and Tenant has
been given five (5) Business Days’ written notice thereof. 
 “Superior Lease(s)” shall mean all ground or
underlying leases of the Real Property or the Building heretofore or hereafter made by Landlord and all renewals, extensions, supplements and modifications thereof. 

“Taxes” shall have the meaning set forth in Section 3.1. 

“Tax Year” shall mean each period of twelve (12) months, commencing on the first day of July of each year, that includes
any part of the Term, or such other period of twelve (12) months as may be duly adopted as the fiscal year for real estate tax purposes by the City of New York. 

  
 7 

 “Tenant”, on the date as of which this Lease is made, shall mean the Tenant
named in this Lease, but thereafter “Tenant” shall mean only the tenant under this Lease at the time in question; provided, however, that the Tenant named in this Lease and any successor tenant hereunder shall not be released from
liability hereunder in the event of any assignment of this Lease. 
 “Tenant Delay” shall mean any actual delay beyond the
anticipated completion date for the matter at issue that Landlord encounters in the performance of Landlord’s obligations under this Lease by reason of (i) any intentional act, negligence or omission (where there is a duty to act) of any
nature of Tenant or Persons Within Tenant’s Control, including, without limitation, delays due to changes in or additions to Landlord’s Work requested by Tenant or Tenant’s failure to timely submit information or to timely give
authorizations or approvals required to be given by Tenant hereunder, or (ii) postponement of any Landlord’s Work at the written request of Tenant. 

“Tenant Indemnitees” shall have the meaning set forth in Section 33.2. 

“Tenant’s BID Payment” shall have the meaning set forth in Section 3.2. 

“Tenant’s Operating Payment” shall have the meaning set forth in Section 3.3. 

“Tenant’s Projected Operating Share” shall have the meaning set forth in Section 3.3. 

“Tenant’s Property” shall mean Tenant’s movable fixtures and movable partitions, telephone and other equipment,
furniture, furnishings and other movable items of personal property, including the personal property of Tenant’s agents and employees. 

“Tenant’s Tax Payment” shall have the meaning set forth in Section 3.2. 

“Unavoidable Delays” shall have the meaning set forth in Article 26. 

ARTICLE 2 
 DEMISE, PREMISES,
TERM, RENT 
 Section 2.1 Landlord hereby leases to Tenant and Tenant hereby hires from Landlord the Premises for the Term to
commence, subject to Article 23, on the Commencement Date and to end on the Fixed Expiration Date, unless earlier terminated or extended as provided herein. Tenant shall also have, as appurtenant to the Premises, the use, on a non-exclusive
basis and in common with the other tenants in the Building (and subject to Landlord’s Rules and Regulations), the common areas of the Building and the Land, including (i) the public lobby, public hallways and public stairways,
(ii) the public elevators, (iii) common walkways necessary for access to the Building, and (iv) all other parts of the Real Property made available by Landlord to all tenants in the Building. 

  
 8 

 Section 2.2 Tenant shall pay to Landlord, in lawful money of the United States of America,
without notice or demand, by good and sufficient check drawn to the Landlord’s order on a bank or trust company with an office in the Borough of Manhattan, the City of New York, State of New York, or by wire transfer, at Tenant’s option at
the office of Landlord or at such other place as Landlord may designate from time to time by fifteen (15) days prior written notice to Tenant, the following: 

(A) commencing upon the Rent Commencement Date, the Fixed Rent, at the annual fixed rental rate set forth in the Reference Page, which shall
be payable in equal monthly installments of Fixed Rent in advance on the first day of each and every calendar month during the Term, except that the first monthly installment of Fixed Rent shall be payable by Tenant upon execution of this Lease; and

 (B) commencing upon the Commencement Date, additional rent (“Additional Rent”) consisting of all other sums of money
(including, without limitation, Escalation Rent) as shall become due from and be payable by Tenant hereunder (for default in the payment of which Landlord shall have the same remedies as for a default in the payment of Fixed Rent). 

Section 2.3 If the Rent Commencement Date is other than the first day of a calendar month, or the Expiration Date is other than the last
day of a calendar month, Fixed Rent for such month shall be prorated on a per diem basis. 
 Section 2.4 Tenant shall pay the Fixed
Rent and Additional Rent when due without abatement, deduction, counterclaim, setoff or defense for any reason whatsoever, except such abatements, deductions, counterclaims, setoffs or defenses as may be occasioned by the occurrence of any event
permitting same as specifically set forth in this Lease. 
 Section 2.5 Landlord may submit to Tenant a written agreement,
substantially in the form annexed as Schedule H, confirming the dates fixed by Landlord, in accordance with the provisions of this Lease, as the Commencement Date, the Rent Commencement Date and the Fixed Expiration Date, and Tenant shall
execute such agreement and return it to Landlord within five (5) Business Days thereafter. Any failure of the parties to execute such written agreement shall not affect the validity of the Commencement Date, the Rent Commencement Date or the
Fixed Expiration Date as fixed and determined by Landlord as aforesaid. If Tenant disputes the Commencement Date, Tenant must notify Landlord of the nature of, and reasons for, such dispute within such five (5) Business Day period. 

ARTICLE 3 
 ESCALATION 

Section 3.1 For the purposes of this Article 3, the following terms shall have the meanings set forth below: 

(A) “Operating Expenses” shall mean the aggregate of those costs and expenses (and taxes thereon, if any) paid or incurred by
Landlord or on behalf of Landlord, without duplication, with respect to the operation, cleaning, repair, safety, replacement, management, security and maintenance of the Real Property, Building Systems, sidewalks, curbs, plazas, and other areas
adjacent to the Building, and with respect to the services provided to tenants, including, without limitation: (i) salaries, wages and bonuses paid to, and the cost of any hospitalization, medical, surgical, union and general welfare benefits
(including group life insurance), any pension, retirement or life insurance plans and other benefits or similar expenses relating to employees of Landlord engaged in the operation, cleaning, repair, safety, replacement,

  
 9 

 
management, security or maintenance of the Real Property and the Building Systems or in providing services generally to tenants; (ii) social security, unemployment and other payroll taxes,
the cost of providing disability and worker’s compensation coverage imposed by any Laws, union contract or otherwise with respect to said employees; (iii) the cost of gas, oil, steam, water, sewer rental, HVAC and other utilities furnished
to the Building and utility taxes; (iv) the expenses incurred for casualty, rent, liability, fidelity, plate glass and any other insurance related to the ownership and operation of the Building; (v) the cost of repairs, maintenance and
painting, including the cost of acquiring or renting all supplies, tools, materials and equipment used in operating or repairing the Building; (vi) expenditures, whether by purchase or lease, for capital improvements and capital equipment that
under generally applied real estate practice are expensed or regarded as deferred expenses and capital expenditures, whether by purchase or lease, that are made to comply with Laws first enacted or first becoming effective after the date of this
Lease or for emergency or labor-saving devices or security or property protection systems or in lieu of a repair, in each case such capital expenditures to be included in Operating Expenses for the Operating Year in which such costs are incurred and
every subsequent Operating Year, on a straight-line basis, to the extent that such items are amortized over their useful lives, determined in accordance with generally accepted accounting principles, consistently applied, with interest calculated at
an annual rate equal to the Applicable Rate in effect at the time of Landlord’s having made said expenditure (provided that with respect to labor-saving devices, the maximum amount that may be included in Operating Expenses for any such capital
equipment or capital expenditure shall not exceed the amount of savings such device has been designed to achieve); (vii) the cost or rental of all supplies, tools, materials and equipment; (viii) the cost of uniforms, work clothes and dry
cleaning; (ix) the cost of window cleaning, janitorial, concierge, guard, watchman or other security personnel, service or system, if any; (x) management fees (not to exceed three percent (3%) of gross revenues derived from the
Building); (xi) charges of independent contractors performing work included within this definition of Operating Expenses; (xii) telephone and stationery costs; (xiii) legal, accounting and other professional fees and disbursements
incurred in connection with the operation and management of the Real Property; (xiv) association fees and dues; (xv) the cost of seasonal decorations (but not permanent works of art); (xvi) depreciation of hand tools and other movable
equipment used in the operation, cleaning, repair, safety, management, security or maintenance of the Building; (xvii) exterior and interior landscaping; and (xviii) all electrical costs incurred in the operation of the Real Property,
other than leaseable areas of the Building. 
 Provided, however, that the foregoing costs and expenses shall exclude or have deducted from
them, as the case may be: 
 (1) compensation for persons above the grade of building manager; 

(2) the cost of any items or services for which Landlord is reimbursed or entitled to be reimbursed from Tenant or other third parties, other
than pursuant to provisions similar in nature to this Article 3; 
 (3) cost of repairs or replacements or restoration incurred by
reason of fire or other casualty or condemnation, except that the amount of any deductible paid by Landlord may be included in Operating Expenses; 

  
 10 

 (4) costs incurred in performing work or furnishing services or utilities for any tenant,
whether at such tenant’s or Landlord’s expense, to the extent that such work or service is in excess of any work or service or utilities that Landlord is obligated to furnish to Tenant at Landlord’s expense; 

(5) Taxes; 
 (6) financing or
refinancing costs and mortgage interest and mortgage amortization payments, all penalties, fines and damages payable under any Mortgage and legal and other professional fees incurred in connection with such financing or refinancing; 

(7) leasing commissions, brokerage commissions, entertainment expenses, rental concessions and lease buy-outs; 

(8) amortization and depreciation, except as otherwise specifically provided in clauses (vi) and (xvi) above and in the first
paragraph (unnumbered) following this list of exclusions; 
 (9) amounts paid to affiliates of Landlord for services to the extent that
such costs exceed the costs of such services were they not rendered by an affiliate of Landlord; 
 (10) rental under any Superior Lease,
other than rental in the nature of an Operating Expense, as described in this Article 3, and all penalties, fines and damages payable under any Superior Lease; 

(11) professional fees (including legal and accounting fees) not allocated to the operation or management of the Real Property and
professional fees (including legal and accounting fees) allocable to disputes with, or preparation of leases for, tenants and prospective tenants or in enforcing any lease or in renewing, extending or amending any lease for a tenant in the Building;

 (12) advertising and marketing and promotional expenses with respect to the Real Property; 

(13) all electrical costs incurred and furnished to leaseable areas of the Building; 

(14) the cost of any demolition, alterations, additions, changes, replacements, improvements and construction to prepare space for occupancy
by a new tenant (including Tenant) or made to the Building solely for the benefit of a new tenant or to renovate space for an existing tenant, and any cash contributions or allowances with respect thereto; 

(15) costs incurred with respect to a sale of all or any portion of the Building or the Land or any interest therein or of any interest in
Landlord or any entity comprising Landlord; 
 (16) to the extent any cost is includable in Operating Expenses and incurred with respect to
both the Building and other properties (including, without limitation, salaries, fringe benefits and other compensation of Landlord’s personnel who provide services to both the Building and other properties), there shall be excluded from
Operating Expenses a fair and reasonable percentage thereof which is properly allocable to such other properties; 

  
 11 

 (17) the cost of the acquisition of the Land or the construction of improvements to the Building
in connection with an expansion thereof; 
 (18) cost of repairs or other work occasioned by the exercise of the right of eminent domain;

 (19) costs incurred to clean up, contain, abate, remove or otherwise remediate Hazardous Materials from the Real Property that have been
determined to be Hazardous Materials as of the date of this Lease; 
 (20) any compensation paid to clerks, attendants, or other persons
engaged in commercial concessions operated by Landlord for profit; 
 (21) costs or expenses associated with the operation of the business
of the entity which constitutes Landlord, such as the formation of the entity, internal accounting and legal matters; 
 (22) permanent
works of art (as distinct from seasonal or other decorations); 
 (23) Landlord’s general corporate overhead and general and
administrative expenses (except that Tenant hereby acknowledges that Operating Expenses shall include a management fee as set forth above); 

(24) costs of items considered capital repairs, replacements, improvements and equipment under generally accepted accounting principles
consistently applied or otherwise, except as expressly provided in Section 3.1(A)(vi) and the penultimate grammatical paragraph of this Section 3.1(A); and 

(25) costs arising form Landlord’s charitable or political contributions. 

If Landlord purchases any item of capital equipment or makes any capital expenditure that is intended to have the effect of reducing the
expenses that would otherwise be included in Operating Expenses, then the costs of such capital equipment or capital expenditure shall be included in Operating Expenses for the Operating Year in which the costs are incurred and every subsequent
Operating Year on a straight-line basis, to the extent that such items are amortized over their useful lives, determined in accordance with generally accepted accounting principles, consistently applied, with interest calculated at the Applicable
Rate in effect at the time of Landlord’s having made said expenditure. If Landlord leases any item of capital equipment designed to result in savings or reductions in expenses that would otherwise be included in Operating Expenses, then the
rentals and other costs paid with respect to such leasing shall be included in Operating Expenses for the Operating Years in which such rentals and costs are incurred. Notwithstanding the provisions of this paragraph, the maximum amount that may be
included in any Operating Year for any such capital equipment or capital expenditure shall not exceed the amount of savings realized by such capital equipment or capital expenditure. To the extent that the amount of such savings is less than the
amortized cost plus interest in any one 

  
 12 

 
Operating Year, Landlord shall include in subsequent Operating Years until fully recovered the amount not included in an Operating Year by reason of such limitation (provided that such limitation
is not exceeded in any subsequent Operating Year). 
 If Landlord is not furnishing any particular work or service (the cost of which if
performed by Landlord would constitute an Operating Expense) to a tenant who has undertaken to perform such work or service in lieu of the performance thereof by Landlord for all or any portion of an Operating Year (including calendar year 2010),
Operating Expenses for such Operating Year shall be deemed to be increased by an amount equal to the additional Operating Expenses which reasonably would have been incurred during such Operating Year by Landlord if it had, at its own expense,
furnished such work or service to such tenant. 
 (B) “Taxes” shall mean the aggregate amount of real estate taxes and any
general or special assessments (exclusive of penalties and interest thereon) payable with respect to the Real Property (including, without limitation, (i) assessments made upon or with respect to any “air” and “development”
rights now or hereafter appurtenant to or affecting the Real Property, (ii) any fee, tax or charge imposed by any Government Authority for any vaults, vault space or other space within or outside the boundaries of the Real Property not used by
and paid for by one or more specified tenants, and (iii) any assessments levied after the date of this Lease for public benefits to the Real Property or the Building, other than BID Charges (as hereinafter defined); provided that if,
because of any change in the taxation of real estate, any other tax or assessment, however denominated (including, without limitation, any franchise, income, profit, sales, use, occupancy, gross receipts or rental tax) is imposed upon Landlord or
the owner of the Real Property or the Building, or the occupancy, rents or income therefrom, in substitution for any of the foregoing Taxes or for an increase in any of the foregoing Taxes, such other tax or assessment shall be deemed part of Taxes
computed as if Landlord’s sole asset were the Real Property. With respect to any Tax Year, all reasonable expenses, including customary attorneys’ fees and disbursements and reasonable experts’ and other witnesses’ fees, incurred
in contesting the validity or amount of any Taxes or in obtaining a refund of Taxes shall be considered as part of the Taxes for such Tax Year. Anything contained herein to the contrary notwithstanding, Taxes shall not be deemed to include
(a) any taxes on Landlord’s income, or profit or corporate taxes, (b) franchise taxes, (c) estate, inheritance, succession, capital stock, gains, transfer or gift taxes, or (d) any similar taxes imposed on Landlord, except
to the extent such taxes are levied, assessed or imposed as a substitute for the whole or any part of, or as a substitute for an increase in, the taxes, assessments, levies, fees, charges and impositions that now constitute Taxes. In no event shall
Taxes include any interest or penalties incurred as a result of Landlord’s late payment of Taxes. Taxes shall be calculated taking into account any abatement or exemption then in effect pursuant to the ICIP. 

(C) “BID Charges” shall mean business improvement district charges imposed on the Building and/or the Land, and any expenses
incurred by Landlord in contesting the same. 
 Section 3.2 

(A) Tenant shall pay as Escalation Rent for each Tax Year, (i) an amount (“Tenant’s Tax Payment”) equal to
Tenant’s Share of the amount by which the Taxes for such Tax Year are greater than the Base Tax Factor and (ii) an amount (“Tenant’s BID Payment”) equal to Tenant’s Share of the BID Charges. Notwithstanding any
provision contained in this 

  
 13 

 
Lease to the contrary, Tenant shall have no obligation to make any Tenant’s Tax payment or any Tenant’s BID Payment with respect to the period prior to the first anniversary of the
Commencement Date. Tenant’s Tax Payment and Tenant’s BID Payment shall be payable by Tenant to Landlord in twelve (12) equal monthly installments (subject to the further provisions of this Section 3.2), the first of which
shall be due within thirty (30) days after receipt of a Landlord’s Tax Statement, regardless of whether such Landlord’s Tax Statement is received prior to, on or after the first day of such Tax Year and the remaining installments
shall be due on the first day of each month thereafter. If there is any increase in Taxes or in BID Charges for any Tax Year, whether during or after such Tax Year, or if there is any decrease in the Taxes or in BID Charges for any Tax Year whether
during or after such Tax Year, Landlord may furnish a revised Landlord’s Tax Statement for any Tax Year affected, and Tenant’s Tax Payment and Tenant’s BID Payment for such Tax Year shall be adjusted and, (a) within thirty
(30) days after Tenant’s receipt of such revised Landlord’s Tax Statement, Tenant shall (with respect to any increase in Taxes and/or BID Charges for such Tax Year) pay the appropriate increase in Tenant’s Tax Payment and/or
Tenant’s BID Payment to Landlord, or (b) (with respect to any decrease in Taxes and/or BID Charges for such Tax Year) Landlord shall, at its election, either credit such decrease in Tenant’s Tax Payment and/or Tenant’s BID
Payment against the next installment(s) of Rental payable by Tenant until fully applied or refund the amount of such decrease by check to the order of Tenant or, if at the end of the Term, there shall not be any further installments of Rental
remaining against which Landlord can credit any decrease in Taxes and/or BID Charges due Tenant, Landlord shall deliver to Tenant Landlord’s check in the amount of the refund due Tenant within thirty (30) days after Landlord’s receipt
of any refund. If, during the Term, Taxes or BID Charges are required to be paid (either to the appropriate taxing authorities or as tax escrow payments to the Lessor or the Mortgagee), in full or in quarterly or other installments on any other date
or dates than as presently required, then Tenant’s Tax Payments and Tenant’s BID Payments shall be correspondingly accelerated or revised so that Tenant’s Tax Payments and Tenant’s BID Payments are due at least thirty
(30) days prior to the date payments are due to the taxing authorities, the Lessor or the Mortgagee. 
 (B) Only Landlord shall be
eligible to institute tax reduction or other proceedings to reduce Taxes or BID Charges, which Landlord shall institute for each Tax Year during the Term so long as Landlord determines there is a reasonable basis therefor. If, after a
Landlord’s Tax Statement has been sent to Tenant, a refund of Taxes or BID Charges is actually received by or on behalf of Landlord, then, promptly after receipt of such refund, Landlord shall send Tenant a Landlord’s Tax Statement
adjusting the Taxes and BID Charges for such Tax Year (taking into account Landlord’s reasonable expenses therefor and any interest paid on such refund) and setting forth Tenant’s Share of such refund, and Tenant shall be entitled to
receive such amount by way of a credit against the next installment(s) of Rental until fully applied or by a refund to Tenant by check within thirty (30) days of Landlord’s receipt of the refund if at the end of the Term; provided,
however, that Tenant’s Share of such refund shall be limited to the amount of Tenant’s Tax Payment or Tenant’s BID Payment as applicable, which Tenant had theretofore paid to Landlord attributable to increases in Taxes or BID Charges
for the Tax Year to which the refund is applicable. 
 (C) Tenant’s Tax Payment and Tenant’s BID Payment and any credits with
respect thereto as provided in this Section 3.2 shall be made as provided in this Section 3.2 regardless of the fact that Tenant may be exempt, in whole or in part, from the payment of any taxes by reason of Tenant’s
diplomatic or other tax exempt status or for any other reason whatsoever. 

  
 14 

 (D) Tenant shall pay to Landlord within thirty (30) days after demand as Additional Rent any
occupancy tax or rent tax now in effect or hereafter enacted, if payable by Landlord with respect to the Premises in the first instance or hereafter required to be paid by Landlord with respect to the Premises. 

(E) Each Landlord’s Tax Statement furnished by Landlord with respect to Tenant’s Tax Payment and Tenant’s BID Payment shall be
accompanied by a copy of the real estate tax bill or bills for the Tax Year referred to therein, but Landlord shall have no obligation to deliver more than one such copy of the real estate tax bill or bills in respect of any Tax Year, and
Landlord’s failure to deliver such copy shall not affect Tenant’s obligations as to amount or due date(s) thereof. 
 (F) If the
Base Tax Factor subsequently shall be adjusted, corrected, reduced or increased, whether as the result of protest, by means of agreement or as the result of legal proceedings, the Base Tax Factor for the purpose of computing any Additional Rent
payable pursuant to this Article shall be the Base Tax Factor as so adjusted, corrected, reduced or increased. Until the Base Tax Factor is so adjusted, corrected, reduced or increased, if ever, Tenant shall pay Additional Rent hereunder based upon
the unadjusted, uncorrected, unreduced or un-increased Base Tax Factor and upon such adjustment, correction, reduction or increase occurring, any Additional Rent payable by Tenant prior to the date of such occurrence shall be recomputed and either
(x) Tenant shall pay to Landlord any Escalation Rent found due by such recomputation within thirty (30) days after being billed therefor (which bill shall set forth in reasonable detail the pertinent data causing and comprising such
recomputation) or (y) Landlord shall deliver to Tenant Landlord’s check in the amount of the refund in Escalation Rent found due by such recomputation within thirty (30) days after Tenant shall first be entitled thereto. 

(G) If the Commencement Date or the Expiration Date occurs on a date other than July 1 or June 30, respectively, any Tenant’s
Tax Payment and Tenant’s BID Payment under this Article 3 for the Tax Year in which such Commencement Date or Expiration Date occurs shall be apportioned in that percentage which the number of days in the period from the Commencement
Date to June 30 or from July 1 to the Expiration Date, as the case may be, both inclusive, bears to the total number of days in such Tax Year. If the Commencement Date or the Expiration Date occurs on a date other than January 1 or
December 31, respectively, any Tenant’s Operating Payment under this Article 3 for the Operating Year in which such Commencement Date or Expiration Date occurs shall be apportioned in that percentage which the number of days in the
period from the Commencement Date to December 31 or from January 1 to the Expiration Date, as the case may be, both inclusive, bears to the total number of days in such Operating Year. In the event of a termination of this Lease, any
Escalation Rent under this Article 3 shall be paid or adjusted within thirty (30) days after submission of a Landlord’s Statement. In no event shall Fixed Rent ever be reduced by operation of this Article 3 and the rights and
obligations of Landlord and Tenant under the provisions of this Article 3 with respect to any Escalation Rent shall survive the Expiration Date. 

  
 15 

 Section 3.3 

(A) Tenant shall pay as Escalation Rent for each Operating Year an amount (“Tenant’s Operating Payment”) equal to
Tenant’s Share of the amount by which Operating Expenses for such Operating Year are greater than the Base Operating Factor. Notwithstanding any provision contained in this Lease to the contrary, Tenant shall have no obligation to make any
Tenant’s Operating Payment with respect to the period prior to the first anniversary of the Commencement Date. 
 (B) Landlord shall
furnish to Tenant, with respect to each Operating Year, a Landlord’s Operating Statement setting forth Landlord’s good faith estimate of Tenant’s Operating Payment for such Operating Year (“Tenant’s Projected Operating
Share”). Tenant shall pay to Landlord on the first day of each month during such Operating Year, as Escalation Rent, an amount equal to one-twelfth of Tenant’s Projected Operating Share for such Operating Year. If, however, Landlord
furnishes any such Landlord’s Operating Statement for an Operating Year subsequent to the commencement of such Operating Year, then (a) until the first day of the month following the month in which such Landlord’s Operating Statement
is furnished to Tenant (but in no event less than thirty (30) days), Tenant shall pay to Landlord on the first day of each month an amount equal to the monthly sum payable by Tenant to Landlord under this Section 3.3 in respect of
the last month of the preceding Operating Year; (b) after such Landlord’s Operating Statement is furnished to Tenant or together therewith, Landlord shall give notice to Tenant stating whether the installments of Tenant’s Projected
Operating Share previously made for such Operating Year were greater or less than the installments of Tenant’s Projected Operating Share to be made for such Operating Year in accordance with such estimate, and (i) if there is a deficiency,
Tenant shall pay the amount thereof within thirty (30) days after demand therefor, or (ii) if there was an overpayment, Landlord shall credit the amount thereof against subsequent payments of Rental until fully applied or, if at the end of
the Term there shall not be any further installments of Rental remaining against which Landlord can credit any such overpayment due Tenant, Landlord shall deliver to Tenant Landlord’s check in the amount of the refund due Tenant within thirty
(30) days after Tenant shall first be entitled to a credit for the overpayment of Operating Expenses; and (c) on the first day of the month following the month in which such Landlord’s Operating Statement is furnished to Tenant (but
in no event less than thirty (30) days), and monthly thereafter throughout the remainder of such Operating Year, Tenant shall pay to Landlord an amount equal to one-twelfth of Tenant’s Projected Operating Share shown in such
Landlord’s Operating Statement. Landlord may furnish to Tenant a revised Landlord’s Operating Statement with a new good faith estimate of Tenant’s Projected Operating Share for such Operating Year and, in such case, Tenant’s
Projected Operating Share for such Operating Year shall be adjusted and paid or credited, as the case may be, substantially in the same manner as provided in the preceding sentence. 

(C) Within one hundred eighty (180) days after the end of each Operating Year, Landlord shall endeavor to furnish to Tenant a
Landlord’s Operating Statement for such Operating Year. Each such year-end Landlord’s Operating Statement shall be accompanied by a computation of Operating Expenses for the Building prepared by the Manager or a certified public accountant
designated by Landlord from which Landlord shall make the computation of Escalation Rent due in respect of Operating Expenses hereunder. In making computations of Operating Expenses, the certified public accountant or the Manager may rely on
Landlord’s reasonable estimates and allocations whenever said estimates and allocations are needed for this 

  
 16 

 
Article 3. If the Landlord’s Operating Statement shows that the sums paid by Tenant under Section 3.3(B) exceeded Tenant’s Operating Payments required to be paid
by Tenant for such Operating Year, Landlord shall credit the amount of such excess against subsequent payments of Rental until fully applied or, if at the end of the Term there shall not be any further installments of Rental remaining against which
Landlord can credit any such overpayments due Tenant, Landlord shall deliver to Tenant Landlord’s check in the amount of the refund due Tenant within thirty (30) days after Tenant shall first be entitled to a credit for the overpayment of
Operating Expenses; and if the Landlord’s Operating Statement for such Operating Year shows that the sums so paid by Tenant were less than Tenant’s Operating Payment due for such Operating Year, Tenant shall pay the amount of such
deficiency within thirty (30) days after demand therefor. 
 Section 3.4 Landlord’s failure to render any Landlord’s
Statement with respect to any Tax Year or Operating Year shall not prejudice Landlord’s right thereafter to render a Landlord’s Statement with respect thereto or with respect to any subsequent Tax Year or Operating Year, as the case may
be, nor shall the rendering of a Landlord’s Statement prejudice Landlord’s right thereafter to render a corrected Landlord’s Statement for that Tax Year or Operating Year; provided, however, that if Landlord shall fail
to furnish a Landlord’s Statement with respect to (i) a Tax Year within two (2) years after the later to occur of (x) the expiration of the Term of this Lease and (y) the date of final settlement with the taxing authority
for Taxes for such Tax Year, or (ii) an Operating Year within two (2) years following the expiration of the Term of this Lease, as the case may be, then Landlord shall be deemed to have irrevocably waived its right to furnish a
Landlord’s Statement with respect to such Tax Year or Operating Year. 
 Section 3.5 Any Landlord’s Statement sent to Tenant
shall be conclusively binding upon Tenant unless, within one hundred eighty days (180) days after such Landlord’s Statement is sent, Tenant shall send a written notice to Landlord objecting to such Landlord’s Statement. If Tenant
shall send such notice with respect to a Landlord’s Operating Statement, then Tenant may, at its own expense, select an auditor which is an independent certified public accountant, who or which is not being compensated by Tenant, in whole or in
part, on a contingency basis (an “Approved Examiner”), provided that such Approved Examiner is not and has not during the Term been affiliated with, a shareholder in, an officer, director, partner, or employee of, any Manager during
the Term or the Manager named in this Lease, and such Approved Examiner may examine Landlord’s books and records relating solely to the Operating Expenses to determine the accuracy of such Landlord’s Operating Statement. In connection
therewith, upon the written request of Tenant, Landlord’s Chief Financial Officer shall certify the amount of the gross revenues derived from the Building for the applicable Operating Year. Tenant recognizes the confidential nature of
Landlord’s books and records and any certification received from Landlord’s Chief Financial Officer with respect to gross revenues, and agrees that information obtained by it or an Approved Examiner during any examination (including any
compromise, settlement or adjustment relating to the results of such examination) shall be maintained in strict confidence by Tenant and such Approved Examiner. As a condition precedent to Tenant’s exercise of its right to examine
Landlord’s books and records, Tenant shall deliver to Landlord a confidentiality agreement, reasonably satisfactory to Landlord (but containing commercially reasonable and standard exceptions to confidentiality), from the Approved Examiner to
the same effect as Tenant’s agreement contained in the preceding sentence. If, after such examination, Landlord’s calculation of Operating Expenses for the Operating Year under inspection was overstated by more than five percent (5%),
then, after verification, Landlord shall reimburse Tenant for its actual reasonable out-of-pocket costs of such examination, within thirty (30) days 

  
 17 

 
after receipt of Tenant’s invoice therefor. If, after such examination, such Approved Examiner shall dispute such Landlord’s Operating Statement, either party may refer the decision of
the issues raised to a reputable independent firm of certified public accountants not affiliated or having had worked for Landlord or Tenant or their respective affiliates within the prior three (3) year period, selected by Landlord and
approved by Tenant, which approval shall not be unreasonably withheld, conditioned or delayed, and the decision of such accountants shall be conclusively binding upon the parties. The fees and expenses involved in resolving such dispute shall be
borne by the unsuccessful party (and if both parties are partially unsuccessful, the accountants shall apportion the fees and expenses between the parties based upon the degree of success of each party). Notwithstanding the giving of such notice by
Tenant, and pending the resolution of any such dispute, Tenant, as a condition of Tenant’s right to challenge a Landlord’s Statement, shall pay to Landlord when due the amount shown on any such Landlord’s Statement, as provided in
this Article 3. The obligations contained in this Section 3.5 shall survive the Expiration Date. 
 Section 3.6 In
determining the amount of the Base Operating Factor and Operating Expenses, if less than 95% of the Building’s rentable area shall have been occupied by tenant(s) at any time during the calendar year 2010 or any subsequent Operating Year,
Operating Expenses, for the purposes of the Base Operating Factor and for any such subsequent Operating Year, shall be adjusted to the amount which would normally be expected to be incurred had 95% of all such areas been occupied throughout 2010 or
any Operating Year. The provisions of this paragraph with respect to adjustments of Operating Expenses for vacancy, shall apply only to Operating Expenses which are variable and which increase in the same relationship to the increase in occupancy in
the Building and shall not apply to any Operating Expenses which do not vary with the level of occupancy in the Building. 
 ARTICLE 4 

ELECTRICITY 

Section 4.1 Tenant shall at all times comply with the rules, regulations, terms and conditions applicable to service, equipment, wiring
and requirements of the public utility supplying electricity to the Building. Landlord shall provide to the Premises, and Tenant agrees that at no time will the electrical connected load in the Premises exceed, in the aggregate six (6) watts
per rentable square foot, exclusive of the electricity required to operate the HVAC System and the base Building mechanical, emergency power, emergency lighting and Class E Systems. Tenant shall not, without Landlord’s prior written consent in
each instance, connect any fixtures, machinery, appliances or equipment to the Building electric distribution system or make any alteration or addition to Tenant’s machinery, appliances or equipment, or the electric system of the Premises, if
the effect thereof would be to increase the electrical load in the Premises over the load specified in this Section 4.1. Landlord’s consent to such request shall not be unreasonably withheld or delayed, taking into consideration the
fact that Landlord will have to reserve additional power for other space in the Building. Should Landlord grant such consent, all additional risers or other equipment required therefor shall be provided by Landlord and the reasonable cost thereof
shall be paid by Tenant within 30 days after Landlord’s demand. Landlord shall not be liable in any way to Tenant for any interruption or failure or defect in the supply or character of electric service furnished to the Premises or for any
loss, damage or expense Tenant may sustain if either the quantity or character of electric service is changed or is 

  
 18 

 
no longer suitable for Tenant’s requirements, whether by reason of any requirement, act or omission of the public utility serving the Building or for any other reason, other than to the
extent resulting from the negligence or willful misconduct of Landlord or its agents. 
 Section 4.2 (A) As of the Commencement Date,
electricity shall be furnished by Landlord to the Premises, and Tenant shall pay to Landlord, as Additional Rent for such service (including the electricity used to operate any units providing HVAC solely to the Premises), the amounts (the
“Electricity Additional Rent”), as determined by one or more submeters purchased and installed by Landlord, at Landlord’s expense (and maintained, repaired and replaced by Landlord, at Landlord’s expense), at charges,
terms and rates, applied to the monthly readings on each such meter or submeter, as set from time to time during the Term by the public utility serving the Building based upon the average rate per kilowatt hour payable by Landlord for the
electricity furnished to the Building during the applicable billing period (computed by dividing the electricity bill for the Building for such period by the total kilowatt hours on such bill), plus an amount equal to five (5%) percent thereof
to reimburse Landlord for administrative services in connection with supplying and billing such electricity, and for line loss. 
 (B) Bills
for the Electricity Additional Rent shall be rendered to Tenant at such time as Landlord may elect but no more frequently than every thirty (30) days, and Tenant shall pay the amount shown thereon to Landlord within thirty (30) days after
the rendering of such bill. 
 (C) Wherever reference is made in this Article to rate(s) or charge(s) of the public utility supplying
electricity to the Building or to increases in such rates or charges, the words rates or charges shall be deemed to include without limitation, any and all (including any new or additional) (i) kilowatt hours or energy charge;
(ii) kilowatts of demand charge; (iii) fuel adjustment charge; (iv) transfer adjustment charge; (v) utility tax; (vi) sales tax; and (vii) any and all other charges and taxes required to be paid by Landlord to the
utility company. 
 Section 4.3 Tenant, at Landlord’s option, shall purchase from Landlord all lighting tubes, lamps, bulbs and
ballasts used in the Premises, and Tenant shall pay to Landlord Landlord’s reasonable and competitive charges for providing and installing the same, as Additional Rent. 

Section 4.4 Landlord shall have the right, in its sole discretion, to select any entity or entities which it desires to have as the
electrical service provider to the Building (including the Premises), and Tenant shall not have the right to select the same or participate in the selection of the same, except and to the extent that any Laws mandate that Tenant have any such
right(s). Any such new electric service provider shall charge electric rates that are competitive with the then existing electric service provider to the Building. 

Section 4.5 Landlord reserves the right to discontinue furnishing electric energy to the Premises at any time upon not less than sixty
(60) days notice to Tenant provided that Landlord shall not exercise such right unless it discontinues furnishing electricity to a substantial portion of the Building and until Tenant, acting diligently, shall be able to obtain electric energy
directly from the electric service provider for the Building. If Landlord exercises such right of termination, this Lease shall continue in full force and effect and shall be unaffected thereby, except only that, from and after the effective date of
such discontinuance, Landlord shall not be 

  
 19 

 
obligated to furnish electric energy to Tenant and Tenant shall no longer be obligated to pay Electricity Additional Rent. If Landlord voluntarily discontinues furnishing electric energy to
Tenant, Landlord shall, prior to the effective date of such discontinuance, at Landlord’s expense, make such changes in panel boards, feeders, risers, wiring and other conductors and equipment to the extent required to permit Tenant to obtain
electric energy directly from the electric service provider for the Building. If, on the other hand, Landlord is required by any Laws to discontinue furnishing electric energy to Tenant, Tenant shall reimburse Landlord promptly upon demand for the
cost incurred by Landlord in making such changes in panel boards, feeders, risers, wiring and other conductors and equipment in order to permit Tenant to obtain electric energy directly from the electric service provider for the Building. 

ARTICLE 5 
 USE AND OCCUPANCY

 Section 5.1 Tenant shall use and occupy the Premises for the Permitted Use and for no other purpose. 

Section 5.2 Tenant shall not use the Premises or any part thereof, or permit the Premises or any part thereof to be used, (1) for
the business of photographic, multilith or multigraph reproductions or offset printing (other than those which are ancillary to an otherwise Permitted Use), (2) for an off-the-street retail commercial banking, thrift institution, loan company,
trust company, depository or safe deposit business accepting deposits from the general public, (3) for the off-the-street retail sale of travelers checks, money orders, drafts, foreign exchange or letters of credit or for the receipt of money
for transmission, (4) by the United States government, the City or State of New York, any foreign government, the United Nations or any agency or department of any of the foregoing having or asserting sovereign immunity, (5) for the
preparation, dispensing or consumption of food or beverages in any manner whatsoever, except for the preparation, dispensing and consumption of food by Tenant’s employees who work in the Premises and Tenant’s invitees (but not invitees who
are invitees solely for the consumption or purchase of food or beverages unrelated to any other business with Tenant) and not for the sale of food to any Persons other than such employees and invitees, (6) as an employment agency, day-care
facility, labor union, school, or vocational training center (except for the training of employees of Tenant intended to be employed at the Premises and for seminars conducted by Tenant for investors, potential investors, employees and other
business professionals), (7) as a barber shop, beauty salon or manicure shop, (8) for product display activities (such as those of a manufacturer’s representative), (9) as offices of any public utility company, (10) for data
processing activities (other than those which are ancillary to an otherwise Permitted Use), (11) for health care activities, (12) for clerical support services or offices of public stenographers or typists (other than those which are
ancillary to an otherwise Permitted Use), (13) as reservation centers for airlines or travel agencies, (14) for retail or manufacturing use, (15) as studios for radio, television or other media, (16) for offices for a real estate
brokerage firm or (17) for any obscene or pornographic purpose or any sort of commercial sex establishment or for exhibition to the public of any obscene or pornographic materials. For purposes of the preceding clause (17),
“pornographic” shall mean that the material or purpose has prurient appeal or relates, directly or indirectly, to lewd or prurient sexual activity and “obscene” shall have the meaning ascribed thereto in New York Penal Law
Section 235.00. Furthermore, the Premises shall not be used for any purpose that would, in Landlord’s reasonable judgment, tend to lower the first-class 

  
 20 

 
character of the Building, create unreasonable or excessive elevator or floor loads, violate the certificate of occupancy of the Building, impair or interfere with any of the Building operations
or the proper and economic heating, air-conditioning, cleaning or any other services of the Building, interfere with the use of the other areas of the Building by any other tenants, or impair the appearance of the Building. 

ARTICLE 6 
 ALTERATIONS

 Section 6.1 
 (A)
Tenant, upon notice to and coordination with Landlord, but without obtaining Landlord’s consent, may make Alterations which (x)(i) do not affect any structural or mechanical portion of the Building or Building Systems, (ii) do not require
that a building permit be obtained, and (iii) are of a decorative nature such as painting, carpeting, wall covering, and the like and (y) when added with any other similar Alterations within the prior twelve month period, costs less than
$75,000 in the aggregate (a “Decorative Alteration”). Tenant shall not make or permit to be made any other Alterations without Landlord’s prior written consent, which consent shall not be unreasonably withheld, conditioned or
delayed, provided that (1) the outside appearance of the Building shall not be affected; (2) the strength of the Building shall not be affected; (3) the structural parts of the Building shall not be affected; (4) no part of the
Building outside of the Premises shall be affected; and (5) the proper functioning of the Building Systems shall not be adversely affected and the use of such systems by Tenant shall not be increased beyond Tenant’s allocable portion of
reserve capacity thereof, if any. Reference is made to Schedule B hereto, which contains the Building Rules and Building Standards for Alterations applicable to the Building, which is incorporated by reference in this Lease. Landlord reserves
the right to make reasonable changes and additions thereto, that are generally applicable to all tenants of the Building; provided, however, that such changes or additions shall not conflict with the express provisions of this Lease.

 (B) (1) Prior to making any Alterations, Tenant shall, at Tenant’s expense, (i) other than with respect to Decorative
Alterations, submit to Landlord six sets of blue lines of final, stamped and detailed plans and specifications (including layout, architectural, electrical, mechanical and structural drawings) that comply with all Laws for each proposed Alteration,
and Tenant shall not commence any such Alteration without first obtaining Landlord’s approval of such plans and specifications, which approval shall not be unreasonably withheld, conditioned or delayed, (ii) at Tenant’s expense,
obtain all permits, approvals and certificates required by any Government Authorities with respect to such Alterations, and (iii) furnish to Landlord certificates evidencing worker’s compensation insurance (covering all persons to be
employed by Tenant, and Tenant’s contractors and subcontractors, in connection with such Alteration) and copies of Tenant’s policies of commercial general liability insurance (including premises operation, bodily injury, personal injury,
death, independent contractors, products and completed operations, broad form contractual liability and broad form property damage coverages) in such form, with such companies, for such periods and in such amounts as Landlord may reasonably approve,
naming Landlord and its agents, any Lessor and any Mortgagee, as additional insureds. Upon completion of such Alteration, Tenant, at Tenant’s expense, shall obtain certificates of final approval of such Alterations required by any Government
Authority (including the 

  
 21 

 
Landmarks Preservation Commission) and shall furnish Landlord with copies thereof, together with the “as-built” plans and specifications for such Alterations. All Alterations shall be
made and performed substantially in accordance with the plans and specifications therefor as approved by Landlord, all Laws and the Rules and Regulations. All materials and equipment to be incorporated in the Premises as a result of any Alterations
shall be first quality and no such materials or equipment shall be subject to any lien, encumbrance, chattel mortgage, title retention or security agreement. In addition, except for Decorative Alterations, any Alteration for which the cost of labor
and materials (as estimated by Landlord’s architect, engineer or contractor) is in excess of Seventy-Five Thousand ($75,000.00) Dollars, shall be performed only under the supervision of a licensed architect reasonably satisfactory to Landlord.

 (2) Landlord shall endeavor to respond to the proposed plans and specifications referred to in Section 6.1 (B)(1)(i) within
ten (10) Business Days after submission (and within five (5) Business Days after any resubmission, if required), but Landlord shall have no liability to Tenant by reason of Landlord’s failure to respond within such time period. If
Landlord shall fail to respond within such time period, however, Landlord’s approval of such plans and specifications shall be deemed granted, provided that Tenant shall have sent Landlord a second request for approval containing the following
language in eighteen-point print: “THIS IS A SECOND REQUEST FOR APPROVAL OF THE PROPOSED PLANS AND SPECIFICATIONS. IF LANDLORD DOES NOT RESPOND TO THIS REQUEST WITHIN FIVE (5) BUSINESS DAYS, LANDLORD’S APPROVAL SHALL BE DEEMED GRANTED
PURSUANT TO THE PROVISIONS OF THE LEASE” and Landlord shall have failed to respond within such time period. Landlord reserves the right to disapprove any plans and specifications in part, to reserve approval of items shown thereon pending its
review and approval of other plans and specifications, and to condition its approval upon Tenant making reasonable revisions to the plans and specifications or supplying additional information. Any disapproval by Landlord shall specify its reasons
for disapproval with sufficient specificity to enable Tenant to amend its plans and specifications. Tenant agrees that any review or approval by Landlord of any plans and/or specifications with respect to any Alteration is solely for Landlord’s
benefit, and without any representation or warranty whatsoever to Tenant or any other Person with respect to the adequacy, correctness or sufficiency thereof or with respect to Laws or otherwise. 

(C) Except as otherwise provided in the Building Rules and Building Standards for Alterations, Tenant shall be permitted to perform
Alterations during Operating Hours, provided that such work does not unreasonably interfere with or unreasonably interrupt the operation and maintenance of the Building or unreasonably interfere with or unreasonably interrupt the use and occupancy
of the Building by other tenants in the Building; provided that Tenant shall not be entitled to have any construction material delivered, or any construction debris removed, during Operating Hours on Business Days, except as set forth in
Section 28.1(B). Otherwise, Alterations shall be performed at Tenant’s expense and at such times and in such manner as Landlord may from time to time reasonably designate. All Alterations (but not Tenant’s Property) shall
become a part of the Building and shall be Landlord’s property from and after the installation thereof and may not be removed or changed without Tenant’s compliance with the applicable provisions of this Article 6. Notwithstanding
the foregoing, if on or before the date Landlord approves Tenant’s plans and specifications (or other documentation) for such Alterations, Landlord notifies Tenant that Landlord is reserving the right to require Tenant to remove any Alterations
designated by Landlord as specialty Alterations (“Specialty  

  
 22 

 
Installations”) which shall be only those that exceed the customary standard types of alterations for general, executive and administrative business offices in Manhattan, then
Landlord, prior to the Fixed Expiration Date or within 15 days after any earlier termination of this Lease, may require Tenant to remove such Specialty Installations and to repair and restore in a good and workmanlike manner to Building standard
condition (reasonable wear and tear excepted) any damage to the Premises or the Building caused by such removal. Without limiting the foregoing, upon the Expiration Date or the earlier termination of the Term, Tenant shall be obligated to remove any
wiring and cabling from the raceways and conduits located in the Premises and installed by Tenant. All Tenant’s Property shall remain the property of Tenant and, on or before the Expiration Date or earlier end of the Term, may be removed from
the Premises by Tenant at Tenant’s option, provided, however, that Tenant shall repair and restore in a good and workmanlike manner to Building standard condition (reasonable wear and tear excepted) any damage to the Premises or the Building
caused by such removal. The provisions of this Section 6.1(C) shall survive the expiration or earlier termination of this Lease. 

(D) (1) All Alterations shall be performed, at Tenant’s sole cost and expense (but subject to the Tenant Improvement Allowance), by
contractors and subcontractors selected by Tenant and approved by Landlord and under the supervision of a construction or project manager selected by Tenant and approved by Landlord, which approval in any such cases shall not be unreasonably
withheld, conditioned or delayed. Prior to making any Alteration, at Tenant’s request, Landlord shall furnish Tenant with a list of contractors who may perform Alterations to the Premises on behalf of Tenant. If Tenant shall enter into a
contract with any contractor set forth on the list, within six months after Landlord shall furnish Tenant with such list, Tenant shall not be required to obtain Landlord’s consent to such contractor unless, prior to entering into a contract
with such contractor or the commencement of work by the contractor, Landlord notifies Tenant that such contractor has been removed from the list. 

(2) Notwithstanding the foregoing, with respect to any Alteration affecting the Class E Systems or security systems of the Building,
(i) Tenant shall employ Landlord’s or the Manager’s designated contractor, and (ii) the Alteration shall, at Tenant’s reasonable expense, be designed by either Landlord’s or the Manager’s engineer. In addition,
Landlord’s or the Manager’s designated expediter shall review any filings with, or other submissions to, applicable Government Authorities in connection with any of Tenant’s Alterations. 

(E) (1) Any mechanic’s lien filed against the Premises or the Real Property for work claimed to have been done for, or materials claimed
to have been furnished to, Tenant shall be cancelled or discharged by Tenant, by payment or filing of the bond required by law, within thirty (30) days after notice to Tenant that such lien shall have been filed, and Tenant shall indemnify and
hold Landlord harmless from and against any and all costs, expenses, claims, losses or damages resulting therefrom by reason thereof. 

(2) If Tenant shall fail to discharge such mechanic’s lien within the aforesaid period, then, in addition to any other right or remedy
of Landlord, Landlord may, but shall not be obligated to, discharge the same either by paying the amount claimed to be due or by procuring the discharge of such lien by deposit in court or bonding, and in any such event, Landlord shall be entitled,
if Landlord so elects, to compel the prosecution of an action for the foreclosure of such mechanic’s lien by the lienor and to pay the amount of the judgment, if any, in favor of the lienor, with interest, costs and allowances. 

  
 23 

 (3) Any amount paid by Landlord for any of the aforesaid charges and for all reasonable expenses
of Landlord (including, but not limited to, reasonable attorneys’ fees and disbursements) incurred in defending any such action, discharging said lien or in procuring the discharge of said lien, with interest on all such amounts at the maximum
legal rate of interest then chargeable to Tenant from the date of payment, shall be repaid by Tenant within thirty (30) days after written demand therefor, and all amounts so repayable, together with such interest, shall be considered
Additional Rent. 
 Section 6.2 (A) In the case of Alterations costing in excess of $75,000, Tenant shall pay to the Manager a fee (the
“Alteration Fee”) equal to $5,000 per month (prorated for a partial month) during the performance of such Alterations. Such Alteration Fee or any portion thereof shall be paid by Tenant to the Manager within five (5) Business
Days after demand therefor. Notwithstanding the foregoing, Tenant shall not be obligated to pay the Alteration Fee for any Alterations as to which Tenant has engaged Tristar Construction, Sweet Construction or Corporate Interiors as the general
contractor, so long as such selected entity is then authorized to perform work in the Building. 
 (B) As an alternative to the payment of
the Alteration Fee as set forth in Section 6.2(A), at Tenant’s election, Tenant may retain the Manager’s construction services division for the construction management of Tenant’s Alterations. In such case, Tenant shall
pay the Manager (i) a “General Conditions” on the entire cost of the Alterations plus (ii) a fee for overhead and profit, to be applied against the cost of such Alterations, such fee to be agreed upon by Tenant and the Manager in
advance. 
 (C) Tenant also shall reimburse Landlord, within thirty (30) days after demand for any reasonable out-of-pocket third
party expense incurred by Landlord for reviewing the plans and specifications for any Alterations or inspecting the progress of completion of the same. 

Section 6.3 Landlord, at Tenant’s expense, and upon the request of Tenant, shall join in any applications for any permits, approvals
or certificates required to be obtained by Tenant in connection with any permitted Alteration (provided that the provisions of the applicable Laws shall require that Landlord join in such application) and shall otherwise cooperate with Tenant in
connection therewith, provided that Landlord shall not be obligated to incur any cost or expense or liability in connection therewith. 

Section 6.4 At Landlord’s request, Tenant shall furnish to Landlord copies of records of all Alterations and of the cost thereof
within thirty (30) days after the completion of such Alterations. 
 Section 6.5 Tenant shall not, at any time prior to or during
the Term, directly or indirectly employ, or permit the employment of, any contractor, mechanic or laborer in the Premises, whether in connection with any Alteration or otherwise, if such employment would interfere or cause any conflict with other
contractors, mechanics or laborers engaged in the construction, maintenance or operation of the Building by Landlord, Tenant or others. In the 

  
 24 

 
event of any such interference or conflict, Tenant, upon demand of Landlord, shall cause all contractors, mechanics or laborers causing such interference or conflict to leave the Building
immediately. 
 Section 6.6 Landlord and Tenant shall cooperate to enable Landlord to obtain a LEED certification for the Building and
for Tenant to obtain a LEED certification for the interior design of the Premises, but will not be obligated to modify Tenant’s Alterations to comply with any LEED certification requirements. 

ARTICLE 7 
 REPAIRS; FLOOR LOAD

 Section 7.1 Tenant, at Tenant’s sole cost and expense, shall take good care of the Premises and the fixtures, equipment and
appurtenances therein and make all repairs thereto as and when needed to preserve them in good working order and condition, except for (a) reasonable wear and tear, (b) obsolescence and (c) damage for which Tenant is not responsible
pursuant to the provisions of Article 13. Except as otherwise provided in this Section 7.1, Tenant shall not be obligated to repair any exterior or structural components of the Building or the Building Systems, except that Tenant
shall maintain the fire and life safety systems and components thereof installed within the Premises and connected to the Class E Systems by entering into a maintenance contract with the Building’s Class E Systems contractor. The design and
decoration of the elevator areas of each floor of the Premises and the public corridors of any floor of the Premises occupied by more than one (1) occupant shall be under the sole control of Landlord. Notwithstanding any provision contained in
this Lease to the contrary, all damage or injury to the Premises, and all damage or injury to any other part of the Building, or to its fixtures, equipment and appurtenances (including the Building Systems), whether requiring structural or
non-structural repairs, caused by the moving of Tenant’s Property or caused by or resulting from any act or wrongful or negligent omission of, or Alterations made by, Tenant or Persons Within Tenant’s Control, shall be repaired by Tenant,
at Tenant’s sole cost and expense, to the reasonable satisfaction of Landlord (if the required repairs are non-structural in nature and do not affect any Building Systems), or by Landlord at Tenant’s sole cost and expense (if the required
repairs are structural in nature or affect any Building Systems). All of the aforesaid repairs shall be performed in a manner and with materials and design of first class and quality consistent with first-class office buildings in the immediate
vicinity of the Building and shall be made in accordance with the provisions of Article 6. If Tenant shall fail, after ten (10) Business Days’ notice (or such shorter period as may be required because of an emergency), to proceed to
diligently pursue repairs required to be made by Tenant, the same may be made by Landlord, at the reasonable expense of Tenant, and the expenses thereof incurred by Landlord, with interest thereon at the Applicable Rate, shall be paid to Landlord,
as Additional Rent, within thirty (30) days after rendition of a bill or statement therefor. Tenant shall give Landlord notice promptly after becoming aware of any defective condition in any Building Systems located in, servicing or passing
through the Premises. 
 Section 7.2 Tenant shall not place a load upon any floor of the Premises which exceeds the per square foot
“live load” for such floor that such floor was designed to carry. Tenant shall not locate or move any safe, heavy machinery, heavy equipment, business machines, freight, bulky matter or fixtures into or out of the Building without
Landlord’s prior 

  
 25 

 
consent, which consent shall not be unreasonably withheld, conditioned or delayed, and Tenant shall make payment to Landlord of Landlord’s reasonable out-of-pocket costs in connection
therewith, plus fifteen (15%) percent for Landlord’s overhead (if such move is not part of an Alteration). If such safe, machinery, equipment, freight, bulky matter or fixture requires special handling (as reasonably determined by
Landlord), Tenant shall employ only persons holding a Master Rigger’s license to do said work. All work in connection therewith shall comply with the Requirements, and shall be done during such hours as Landlord may reasonably designate.
Business machines and mechanical equipment shall be placed and maintained by Tenant, at Tenant’s expense, in settings sufficient, in Landlord’s reasonable judgment, to absorb and prevent vibration, noise and annoyance. 

Section 7.3 Landlord (at its expense, but subject to the reimbursement by Tenant under the provisions of Article 3 to the extent
permitted thereby) shall operate, maintain and make all necessary repairs (both structural and non-structural) to the Building Systems (including the maintenance and all necessary repairs and replacements of the DX Unit) and the common areas and
other public portions of the Building, both exterior and interior, in conformance with standards applicable to first-class office buildings in the immediate vicinity of the Building, except for those repairs for which Tenant is responsible pursuant
to any other provision of this Lease. Landlord shall use reasonable efforts to minimize interference with Tenant’s use and occupancy of the Premises in making any repairs, alterations, additions or improvements; provided, however, that Landlord
shall have no obligation to employ contractors or labor at so-called overtime or other premium pay rates or to incur any other overtime costs in connection with such repairs, alterations, additions or improvements. Notwithstanding the foregoing, if
Tenant shall so request, Landlord shall employ contractors or labor at so-called overtime or other premium pay rates or incur other overtime costs in making such repairs, alterations, additions or improvements, provided Tenant shall pay to Landlord,
as Additional Rent, within thirty (30) days after demand therefor, an amount equal to the reasonable, out-out-of-pocket overtime costs incurred by Landlord by reason of compliance with Tenant’s request. Except as expressly provided in this
Lease, there shall be no allowance to Tenant for a diminution of rental value and no liability on the part of Landlord by reason of inconvenience, annoyance or injury to business arising from Landlord, Tenant or others making, or failing to make,
any repairs, alterations, additions or improvements in or to any portion of the Building or the Premises, or its fixtures, appurtenances or equipment. 

ARTICLE 8 
 WINDOW CLEANING

 Section 8.1 Tenant shall not clean, nor require, permit, suffer or allow any window in the Premises to be cleaned, from the
outside in violation of Section 202 of the Labor Law, or any other applicable law, or of the rules of the Board of Standards and Appeals, or of any other board or body having or asserting jurisdiction. 

  
 26 

 ARTICLE 9 

REQUIREMENTS OF LAW 

Section 9.1 Tenant shall not do, and shall not permit Persons Within Tenant’s Control to do, any act or thing in or upon the
Premises or the Building which will invalidate or be in conflict with the certificate of occupancy for the Premises or the Building or violate any Requirements. Tenant shall, at Tenant’s sole cost and expense, take all action, including making
any required Alterations necessary to comply with all Laws (including, but not limited to, applicable terms of Local Laws No. 5 of 1973, No. 16 of 1984, No. 76 of 1985, No. 58 of 1987 and the Americans With Disabilities Act of 1990 (the
“ADA”), each as modified and supplemented from time to time) which shall impose any violation, order or duty upon Landlord or Tenant arising from, or in connection with, the Premises, Tenant’s occupancy, use or manner of use of
the Premises (including, without limitation, any occupancy, use or manner of use that constitutes a “place of public accommodation” under the ADA), or any installations in the Premises, or required by reason of a breach of any of
Tenant’s covenants or agreements under this Lease, whether or not such Laws shall now be in effect or hereafter enacted or issued, and whether or not any work required shall be ordinary or extraordinary or foreseen or unforeseen at the date
hereof. Notwithstanding the preceding sentence, Tenant shall not be obligated to perform any Alterations necessary to comply with any Requirements, unless compliance shall be required by reason of (i) any cause or condition arising out of any
Alterations or installations in the Premises made by Tenant or by Landlord on behalf of Tenant (other than Landlord’s Work and any other Alterations or installations made by Landlord prior to the Commencement Date to prepare the Premises for
Tenant’s occupancy), or (ii) Tenant’s particular use, manner of use or occupancy on behalf of Tenant of the Premises (as opposed to mere office use), or (iii) any breach of any of Tenant’s covenants or agreements under this
Lease, or (iv) any wrongful act or wrongful or negligent omission by Tenant or Persons Within Tenant’s Control, or (v) Tenant’s use or manner of use or occupancy of the Premises as a “place of public accommodation”
within the meaning of the ADA, in which event Tenant’s obligation to perform any Alteration by reason of this clause (v) shall apply only to the Premises. Notwithstanding the foregoing or any other provision of this Lease to the contrary,
Tenant shall comply with all Laws with respect to all restrooms on any full floor of the Premises (whether or not any such restroom is existing as of the date of this Lease and whether or not Tenant has retrofitted or altered the same) and with
respect to all elevator lobbies serving any full floor of the Premises (whether or not Tenant has retrofitted or altered any such elevator lobby); such compliance shall include the making of any Alterations that may be required by any Laws
(provided, however, that Landlord shall deliver the core restrooms and the elevator lobby on the third floor of the Building to Tenant on the Commencement Date in compliance with all applicable Laws, including the ADA.). 

Section 9.2 (a) Tenant covenants and agrees that Tenant shall, at Tenant’s sole cost and expense, comply at all times with all Laws
governing the use, generation, storage, treatment and/or disposal of any Hazardous Materials (as defined below), the presence of which results from the act or omission of Tenant or Persons Within Tenant’s Control or the breach of this Lease by
Tenant or Persons Within Tenant’s Control. The term “Hazardous Materials” shall mean any biologically or chemically active or other toxic or hazardous wastes, pollutants or substances, including, without limitation, asbestos,
PCBs, petroleum products and by-products, substances defined or listed as “hazardous substances” or “toxic substances” or similarly identified in or pursuant to the Comprehensive Environmental Response, Compensation and

  
 27 

 
Liability Act, 42 U.S.C. § 9601 et seq., and as hazardous wastes under the Resource Conservation and Recovery Act, 42 U.S.C. § 6010, et seq., any chemical substance or
mixture regulated under the Toxic Substance Control Act of 1976, as amended, 15 U.S.C. § 2601, et seq., any “toxic pollutant” under the Clean Water Act, 33 U.S.C. § 466 et seq., as amended, any hazardous air
pollutant under the Clean Air Act, 42 U.S.C. § 7401 et seq., hazardous materials identified in or pursuant to the Hazardous Materials Transportation Act, 49 U.S.C. § 1802, et seq., and any hazardous or toxic substances or
pollutant regulated under any other Laws. Tenant shall agree to execute, from time to time, at Landlord’s request, reasonable affidavits, representations and the like concerning Tenant’s knowledge and belief regarding the presence of
Hazardous Materials in, on, under or about the Premises, the Building or the Land. Tenant shall indemnify and hold harmless all Indemnitees from and against any loss, cost, damage, liability or expense (including reasonable attorneys’ fees and
disbursements) arising by reason of any remediation, detoxification action or any other activity required or recommended of any Indemnitees by any Government Authority by reason of the presence in or about the Building or the Premises of any
Hazardous Materials, as a result of the act or omission of Tenant or Persons Within Tenant’s Control or the breach of this Lease by Tenant or Persons Within Tenant’s Control. Landlord shall indemnify and hold harmless Tenant from and
against any loss, cost, damage, liability or expense (including reasonable attorney’s fees and disbursements) arising by reason of any remediation, detoxification action or any other activity required of Tenant by any Governmental Authority by
reason of the release in or about the Building or the Premises of any Hazardous Material prior to Tenant’s occupancy of the Premises or the presence in or about the Building or the Premises of any Hazardous Materials as a result of any act or
omission of Landlord or any Person Within Landlord’s Control or the breach of this Lease by Landlord. The foregoing covenants and indemnities shall survive the expiration or any termination of this Lease. 

(b) Tenant acknowledges that there are certain areas of vinyl asbestos tile (“VAT”) encapsulated in accordance with Laws in
the floor of the Premises. If Tenant desires to make any Alterations which will require trenching or core drilling, Tenant will indicate on its plans and specifications the locations where such work is to be done and submit the same to Landlord for
its approval. If an area of trenching or core drilling indicated on Tenant’s plans and specifications contains VAT, then Landlord will perform the trenching or core drilling in such area at Tenant’s expense, and Landlord will remediate or
encapsulate the VAT in such area in accordance with Laws at Landlord’s expense. 
 Section 9.3 If Tenant shall receive notice of
any violation of, or defaults under, any Requirements, liens or other encumbrances applicable to the Building or the Premises, Tenant shall give prompt notice thereof to Landlord. 

Section 9.4 If any governmental license or permit shall be required for the proper and lawful conduct of Tenant’s business and if
the failure to secure such license or permit would, in any way, affect Landlord or the Building, then Tenant, at Tenant’s expense, shall promptly procure and thereafter maintain, submit for inspection by Landlord, and at all times comply with
the terms and conditions of, each such license or permit. 
 Section 9.5 Tenant, at Tenant’s sole cost and expense and after
notice to Landlord, may contest, by appropriate proceedings prosecuted diligently and in good faith, the legality or applicability of any Laws affecting the Premises provided that: (a) neither Landlord nor any

  
 28 

 
Indemnitees shall be subject to criminal penalties, nor shall the Real Property or any part thereof be subject to being condemned or vacated, nor shall the certificate of occupancy for the
Premises or the Building be suspended or threatened to be suspended, by reason of non-compliance or by reason of such contest; (b) such non-compliance or contest shall not constitute or result in a violation (either with the giving of notice or
the passage of time or both) of the terms of any Mortgage or Superior Lease, or if such Superior Lease or Mortgage conditions such non-compliance or contest upon the taking of action or furnishing of security by Landlord, such action shall be taken
or such security shall be furnished at the expense of Tenant; and (c) Tenant shall keep Landlord regularly advised as to the status of such proceedings. 

Section 9.6 Within thirty (30) days after Tenant’s submission to Landlord of final Plans referred to in the Work Agreement
annexed as Schedule C and Landlord’s approval of such Plans, Landlord shall deliver to Tenant an ACP-5 certificate with respect to the Premises. Landlord shall remove, treat or encapsulate, in accordance with applicable Laws, at its
expense, any asbestos-containing materials existing in the Premises or discovered in the Premises during the Term, so long as such asbestos-containing materials were not introduced into the Premises by Tenant or by Persons Within Tenant’s
Control. 
 Section 9.7 Landlord shall comply with all Laws (including the ADA) which shall impose a duty on Landlord or Tenant with
respect to the Premises or the Real Property with which Tenant is not obligated to comply, if and solely to the extent that (x) such non-compliance by Landlord prevents or impairs Tenant’s ability to use the Premises for its normal
business operations or precludes the issuance of a temporary or permanent certificate of occupancy with respect to the Premises; or (y) as the result of such non-compliance by Landlord, a Government Authority shall issue a fine or other
monetary sanction, an injunction or an enforcement order against Tenant (unless Landlord shall indemnify Tenant therefor). 
 ARTICLE 10 

SUBORDINATION 

Section 10.1 Except as otherwise provided in Section 10.6(B), this Lease shall be subject and subordinate to the lien of each
Superior Lease and to each Mortgage, whether made prior to or after the execution of this Lease, and to the lien of all renewals, extensions, supplements, amendments, modifications, consolidations and replacements thereof or thereto, substitutions
therefor, and advances made thereunder. This clause shall be self-operative and no further agreement of subordination shall be required to make the interest of any Lessor or Mortgagee superior to the interest of Tenant hereunder. In confirmation of
such subordination, however, Tenant shall promptly execute and deliver, at its own cost and expense, any reasonable document, in recordable form if requested, that Landlord, any Lessor or any Mortgagee may request to evidence such subordination. If,
in connection with the financing of the Real Property, the Building or the interest of the lessee under any Superior Lease, or if, in connection with the entering into of a Superior Lease, any lending institution or Lessor, as the case may be,
requests reasonable modifications of this Lease that do not increase Rental or change the Term of this Lease, or materially and adversely affect either the rights or obligations of Tenant or the obligations of Landlord under this Lease, Tenant shall
make such modifications. 

  
 29 

 Section 10.2 If, at any time prior to the expiration of the Term, any Superior Lease shall
terminate or shall be terminated for any reason, or any Mortgagee comes into possession of the Real Property or the Building or the estate created by any Superior Lease by receiver or otherwise, Tenant shall attorn, from time to time, to any such
owner, Lessor or Mortgagee or any person acquiring the interest of Landlord as a result of any such termination, or as a result of a foreclosure of the Mortgage or the granting of a deed in lieu of foreclosure, upon the then executory terms and
conditions of this Lease (except as provided below), for the remainder of the Term, provided that such owner, Lessor or Mortgagee, as the case may be, or receiver caused to be appointed by any of the foregoing, is then entitled to possession of the
Premises. Any such attornment shall be made upon the condition that no such owner, Lessor or Mortgagee shall be: 
 (1) liable for any act
or omission of any prior landlord (including, without limitation, the then defaulting landlord) but shall remain obligated to remedy any continuing defaults; or 

(2) subject to any defense, abatement, or offsets (except as expressly set forth in this Lease) which Tenant may have against any prior
landlord (including, without limitation, the then defaulting landlord); or 
 (3) bound by any payment of Rental which Tenant might have
paid for more than one month in advance of its due date to any prior landlord (including, without limitation, the then defaulting landlord); or 

(4) bound by any obligation to make any payment to Tenant which was required to be made prior to the time such owner, Lessor or Mortgagee
succeeded to any prior landlord’s interest; or 
 (5) bound by any obligation to perform any work or to make improvements to the
Premises except for (i) repairs and maintenance pursuant to the provisions of Article 7 and compliance with Law obligations under Article 9, (ii) repairs to the Premises or any part thereof as a result of damage by fire or
other casualty pursuant to Article 13, but only to the extent that such repairs can be reasonably made from the net proceeds of any insurance actually made available to such owner, Lessor or Mortgagee, and (iii) repairs to the Premises
as a result of a partial condemnation pursuant to Article 14, but only to the extent that such repairs can be reasonably made from the net proceeds of any award made available to such owner, Lessor or Mortgagee. The provisions of this
Section 10.2 shall inure to the benefit of any such owner, Lessor or Mortgagee, shall apply notwithstanding that, as a matter of law, this Lease may terminate upon the termination of any such Superior Lease, and shall be self-operative
upon any such demand, and no further agreement shall be required to give effect to said provisions. Tenant, however, upon demand of any such owner, Lessor or Mortgagee, shall execute, from time to time, agreements in confirmation of the foregoing
provisions of this Section 10.2, reasonably satisfactory to any such owner, Lessor or Mortgagee, and to Tenant, and acknowledging such attornment and setting forth the terms and conditions of its tenancy. 

Section 10.3 Subject to Section 10.6 hereof, if requested by any Mortgagee, any Lessor or Landlord, Tenant shall promptly
execute and deliver, at Tenant’s own cost and expense, any document in accordance with the terms of this Article 10, in recordable form, to evidence such subordination and non-disturbance. 

  
 30 

 Section 10.4 At any time and from time to time within fifteen (15) Business Days after
notice to Tenant or Landlord given by the other, or to Tenant given by a Lessor or Mortgagee (which fifteen (15) Business Day period is not subject to any notice and cure periods otherwise provided in this Lease), Tenant or Landlord, as the
case may be, shall, without charge, execute, acknowledge and deliver a statement in writing addressed to such party as Tenant, Landlord, Lessor or Mortgagee, as the case may be, may designate, in form reasonably satisfactory to Tenant, Landlord,
Lessor or Mortgagee, as the case may be, certifying all or any of the following: (i) that this Lease is unmodified and in full force and effect (or if there have been modifications, that this Lease is in full force and effect as modified and
stating the modifications); (ii) whether the Term has commenced and Fixed Rent and Additional Rent have become payable hereunder and, if so, the dates to which they have been paid; (iii) whether or not, to the best knowledge of the signer
of such certificate, Landlord is in default in performance of any of the terms of this Lease and, if so, specifying each such event of default of which the signer may have knowledge; (iv) whether Tenant has accepted possession of the Premises;
(v) whether Tenant has made any claim against Landlord under this Lease and, if so, the nature thereof and the dollar amount, if any, of such claim; (vi) either that Tenant does not know of any default in the performance of any provision
of this Lease or specifying the default of which Tenant may have knowledge; and (vii) such further reasonable information with respect to this Lease or the Premises as Landlord or Tenant may reasonably request or Lessor or Mortgagee may
require; it being intended that any such statement delivered pursuant hereto may be relied upon by any prospective purchaser of the Real Property or any part thereof or of the interest of Landlord in any part thereof, by any Mortgagee or prospective
Mortgagee, by any Lessor or prospective Lessor, by any tenant or prospective tenant of the Real Property or any part thereof, or by any prospective assignee of any Mortgage or by any assignee or subtenant of Tenant. 

The failure of either Tenant or Landlord to execute, acknowledge and deliver to the other a statement in accordance with the provisions of
this Section 10.4 within said fifteen (15) Business Day period shall constitute an acknowledgment by Tenant or Landlord, as the case may be, which may be relied on by any person who would be entitled to rely upon any such statement,
that such statement as submitted by Landlord or Tenant, as the case may be, is true and correct. 
 Section 10.5 As long as any
Superior Lease or Mortgage exists, Tenant shall not seek to terminate this Lease by reason of any act or omission of Landlord until Tenant has given written notice of such act or omission to all Lessors and Mortgagees at such addresses as may have
been furnished to Tenant by such Lessors and Mortgagees and, if any such Lessor or Mortgagee, as the case may be, notifies Tenant within forty-five (45) days following receipt of such notice of its intention to remedy such act or omission,
until a reasonable period of time (not to exceed 150 days) shall have elapsed following the giving of such notice, during which period such Lessors and Mortgagees shall have the right, but not the obligation, to remedy such act or omission. 

Section 10.6 (A) (i) Simultaneously with its execution and delivery of this Lease, Tenant shall execute and deliver to Landlord a
non-disturbance agreement in the form of Schedule G annexed hereto. Landlord, at its cost and expense, shall use commercially reasonable efforts to cause the existing Mortgagee to execute and deliver to Tenant such non-disturbance agreement
within sixty (60) days after the execution and delivery of this Lease by Landlord and Tenant. Notwithstanding the foregoing, in the event that Tenant shall negotiate the non-disturbance agreement with the existing Mortgagee for any changes to
the form annexed as 

  
 31 

 
Schedule G hereto, Tenant shall reimburse Landlord upon demand for any and all actual out-of-pocket costs and expenses (including, without limitation, reasonable attorneys’ fees and
disbursements) incurred or payable by Landlord in connection with such negotiation of the non-disturbance agreement. Landlord represents that there is no Superior Lease affecting the Real Property as of the date of this Lease. Except as expressly
set forth in Section 10.6(A)(ii) below, Landlord shall have no liability to Tenant if the existing Mortgagee refuses to deliver the non-disturbance agreement in favor of Tenant, and this Lease shall continue in full force and effect 

(ii) Notwithstanding the foregoing, if Landlord shall fail to deliver to Tenant within sixty (60) days after the execution and delivery
of this Lease by Landlord and Tenant a non-disturbance agreement from the existing Mortgagee in the form of Schedule G annexed hereto (the “Existing Mortgagee NDA”), then Tenant may, as its sole and exclusive remedy for
Landlord’s failure to obtain the Existing Mortgagee NDA, terminate this Lease upon ten (10) days prior written notice to Landlord given within the ten (10) day period immediately after such sixty (60) day period (but prior to the
delivery to Tenant of the Existing Mortgagee NDA), time being of the essence with respect to Tenant’s exercise of Tenant’s right to terminate and, if Tenant shall give such notice, this Lease shall terminate effective as of the tenth
(10th) day after the date such notice is given by Tenant to Landlord as if the termination date were the Fixed Expiration Date, and neither party shall have any further liability to the other except that Landlord shall refund to Tenant the
first installment Fixed Rent and the Security Deposit (provided that the same were delivered upon execution of this Lease); provided further, however, that if the Existing Mortgagee NDA shall be delivered prior to such tenth
(10th) day or if Tenant shall not have exercised its right to terminate this Lease in accordance with this sentence, then, in either case, Tenant’s right to terminate this Lease shall be void and of no force or effect. 

(B) As a condition precedent to Tenant’s obligation to subordinate this Lease to any future Mortgage or Superior Lease, Landlord shall
obtain from the holder of such future Mortgage or the Lessor under such future Superior Lease a commercially reasonable non-disturbance agreement in favor of Tenant that provides in substance that, so long as Tenant shall not then be in default in
the performance of any of its obligations under this Lease beyond any applicable notice and cure period, Tenant’s possession of the Premises in accordance with this Lease shall not be disturbed by such Person giving the non-disturbance
agreement or any successor or purchaser at a foreclosure sale (as the case may be) which shall succeed to the rights of Landlord under this Lease. Landlord shall have no liability to Tenant if such holder or Lessor refuses to deliver the
non-disturbance agreement in favor of Tenant. Such non-disturbance agreement shall be in such form as is commercially reasonable and is customarily used by the Mortgagee or Lessor. Tenant shall execute such form, provided the same is commercially
reasonable. If Tenant negotiates with any holder of a future Mortgage or Lessor under a future Superior Lease the non-disturbance agreement customarily used by it, for any protections in addition to those set forth in the form annexed as Schedule
G hereto, Tenant shall reimburse Landlord upon demand for any and all out-of-pocket costs and expenses (including, without limitation, reasonable attorneys’ fees and disbursements) incurred or payable by Landlord in connection with such
negotiation of the non-disturbance agreement. 

  
 32 

 ARTICLE 11 

RULES AND REGULATIONS 

Section 11.1 Tenant and Persons Within Tenant’s Control shall comply with the Rules and Regulations. Nothing contained in this Lease
shall be construed to impose upon Landlord any duty or obligation to enforce the Rules and Regulations or the terms, covenants or conditions in any other lease against any other tenant, and Landlord shall not be liable to Tenant for violation of the
same by any other tenant, its employees, agents, visitors or licensees. Landlord shall not discriminate against Tenant in enforcing the Rules and Regulations. In case of any conflict or inconsistency between the provisions of this Lease and of any
of the Rules and Regulations as originally or as hereinafter adopted, the provisions of this Lease shall control. 
 ARTICLE 12 

INSURANCE, PROPERTY LOSS OR DAMAGE; REIMBURSEMENT 

Section 12.1 
 (A) Neither
Tenant nor Persons Within Tenant’s Control shall entrust any Tenant’s Property to any Building employee. Any Building employee to whom any Tenant’s Property is entrusted by or on behalf of Tenant in violation of the foregoing
prohibition shall be deemed to be acting as Tenant’s agent with respect to such Tenant’s Property and neither Landlord nor its agents shall be liable for any damage to Tenant’s property or property of others entrusted to employees of
the Building, nor for the loss of or damage to any such property by theft or otherwise. Landlord and Landlord’s agents shall not be liable for any damage to any of Tenant’s Property or for interruption of Tenant’s business, however
caused, including but not limited to damage caused by other tenants or persons in the Building. Landlord shall not be liable for any latent defect in the Premises or in the Building, except as set forth in Article 21. The foregoing shall not
relieve Landlord from liability to Tenant (other than for consequential damages) directly resulting from the negligence or willful misconduct of Landlord, its employees and agents. 

(B) If at any time any windows of the Premises are temporarily closed, darkened or covered for any reason whatsoever, including
Landlord’s own acts, or any of such windows are permanently closed, darkened or bricked-up by reason of any Requirements, Landlord shall not be liable for any damage Tenant may sustain thereby, and Tenant shall not be entitled to any
compensation therefor nor abatement of Fixed Rent or any other item of Rental, nor shall the same release Tenant from Tenant’s obligations hereunder nor constitute an eviction. Landlord shall endeavor to (i) give Tenant notice (which
notice may be given orally, notwithstanding the provisions of Article 27) prior to any temporary closing, darkening or bricking-up of any windows by reason of repairs, maintenance, alterations or improvements, and (ii) cause any such
work to be performed as expeditiously as is practicable and in a manner designed to minimize any interference with Tenant’s business operations at the Premises, but Landlord’s failure to so notify Tenant or to cause such work to be
completed expeditiously shall not impose any liability upon Landlord. 

  
 33 

 (C) Tenant shall give notice to Landlord promptly after Tenant learns of any accident, emergency,
occurrence for which Landlord might be liable, fire or other casualty and all damages to or defects in the Premises or the Building for the repair of which Landlord might be responsible or which constitutes Landlord’s property. Such notice
shall be given by telecopy or personal delivery to the address(es) of Landlord in effect for notice. 
 Section 12.2 Tenant shall not
do or permit to be done any act or thing in or upon the Premises which will invalidate or be in conflict with the terms of the New York State standard policies of fire insurance and liability (hereinafter referred to as “Building
Insurance”); and Tenant, at Tenant’s own expense, shall comply with all rules, orders, regulations and requirements of all insurance boards (except for structural changes, repairs or Laws with which Landlord is otherwise required to
comply under this Lease), and shall not do or permit anything to be done in or upon the Premises or bring or keep anything therein or use the Premises in a manner which increases the rate of premium for any of the Building Insurance over the rate in
effect at the commencement of the Term of this Lease. 
 Section 12.3 If by reason of any failure of Tenant to comply with the
provisions of this Lease, the rate of premium for Building Insurance or other insurance on the property and equipment of Landlord shall increase, Tenant shall reimburse Landlord for that part of the insurance premiums thereafter paid by Landlord
which shall have been charged because of such failure by Tenant. Tenant shall make said reimbursement within thirty (30) days of Landlord’s submission to Tenant of an invoice therefor, together with customary back-up documentation. 

Section 12.4 
 (A) Tenant,
at Tenant’s sole cost and expense, shall obtain, maintain and keep in full force and effect during the Term commercial general liability insurance in a form approved in New York State (including coverage for contractual liability recognizing
the indemnity provisions of this Lease to the extent covered by the Commercial General Liability policy and protecting the Indemnitees as required, whether or not Tenant is negligent or otherwise responsible for the additional insured’s loss,
liability or expense). The limits of liability shall be not less than Five Million and 00/100 ($5,000,000.00) Dollars per occurrence, which amount may be satisfied with a primary commercial general liability policy of not less than $1,000,000.00 per
occurrence / $2,000,000.00 general aggregate and an excess (or “Umbrella”) liability policy affording coverage, at least as broad as that afforded by the primary commercial general liability policy, in an amount not less than the
difference between $5,000,000 and the amount of the primary policy. Landlord, the Manager, any Lessors and any Mortgagees shall be included as additional insureds in said policies and shall be protected against all liability, to the extent covered
by the Commercial General Liability policy, arising in connection with this Lease, whether or not Tenant is negligent or otherwise responsible for the additional insured’s loss, liability or expense. All said policies of insurance shall be
written as “occurrence” policies with general aggregate limit provided on a “per location” basis. Whenever, in Landlord’s reasonable judgment, good business practice and changing conditions indicate a need for additional
amounts or different types of insurance coverage, Tenant shall, within ten (10) days after Landlord’s request, obtain such insurance coverage, at Tenant’s expense. 

  
 34 

 (B) Tenant, at Tenant’s sole cost and expense, shall obtain, maintain and keep in full force
and effect during the Term: (i) “All Risk” insurance, with deductibles in an amount reasonably satisfactory to Landlord, protecting and indemnifying Tenant against any and all damage to or loss of any Alterations and leasehold
improvements, including any made by Landlord to prepare the Premises for Tenant’s occupancy, and Tenant’s Property. Such insurance shall not contain any exclusions for flood, mold/fungus (subject to the policy’s $50,000 coverage
carve-back) or acts of terrorism or similar events. All said policies shall cover the full replacement value of all Alterations, leasehold improvements and Tenant’s Property; (ii) Workers’ compensation and occupational disease
insurance, employee benefit insurance or any other insurance in the statutory amounts required by the laws of the State of New York with broad form all-states endorsement, and employer’s liability insurance with a limit of One Million
($1,000,000.00) Dollars for each accident and (iii) Business interruption insurance (including Extra Expense) fully compensating for the amount of Fixed Rent, additional rent and other charges owed to Landlord by Tenant for a period of not less
than twelve (12) months. The coverage shall be “All Risk” (subject to policy terms, conditions and exclusions) as stated in clause (i) above. 

(C) The Commercial General Liability policy of insurance shall be (i) written as primary policy coverage and not contributing with or in
excess of any coverage which Landlord or any Lessor may carry; and (ii) issued by reputable and independent insurance companies rated in Best’s Insurance Guide or any successor thereto (or, if there is none, an organization having a
national reputation), as having a general policyholder rating of “A” and a financial rating of at least “13”, and which are licensed to do business in the State of New York. Tenant shall, not later than ten (10) Business
Days prior to the Commencement Date, deliver to Landlord the policies of insurance and shall thereafter furnish to Landlord, at least fifteen (15) days prior to the expiration of any such policies and any renewal thereof, a new policy in lieu
thereof. Each of said policies shall also contain a provision whereby the insurer agrees not to cancel or fail to renew said insurance policy(ies) without having given Landlord, the Manager and any Lessors and Mortgagees at least thirty
(30) days prior written notice thereof. Tenant shall promptly send to Landlord a copy of all notices sent to Tenant by Tenant’s insurer relating to the Premises. 

(D) Tenant shall pay all premiums and charges for all of said policies, and, if Tenant shall fail to make any payment when due or carry any
such policy, Landlord may, but shall not be obligated to, make such payment or carry such policy, and the amount paid by Landlord, with interest thereon (at the Applicable Rate), shall be repaid to Landlord by Tenant on demand, and all such amounts
so repayable, together with such interest, shall be deemed to constitute Additional Rent hereunder. Payment by Landlord of any such premium, or the carrying by Landlord of any such policy, shall not be deemed to waive or release the default of
Tenant with respect thereto. 
 Section 12.5 

(A) Landlord shall cause each policy carried by Landlord insuring the Building against loss, damage or destruction by fire or other casualty,
and Tenant shall cause each insurance policy carried by Tenant and insuring the Premises and Tenant’s Alterations, leasehold improvements and Tenant’s Property against loss, damage or destruction by fire or other casualty, to be written in
a manner so as to provide that the insurance company waives all 

  
 35 

 
rights of recovery by way of subrogation against Landlord, Tenant and any tenant of space in the Building in connection with any loss or damage covered by any such policy. Neither party shall be
liable to the other for the amount of such loss or damage which is in excess of the applicable deductible, if any, caused by fire or any of the risks enumerated in its policies, provided that such waiver was obtainable at the time of such loss or
damage. However, if such waiver cannot be obtained, or shall be obtainable only by the payment of an additional premium charge above that which is charged by companies carrying such insurance without such waiver of subrogation, then the party
undertaking to obtain such waiver shall notify the other party of such fact and such other party shall have a period of ten (10) days after the giving of such notice to agree in writing to pay such additional premium if such policy is
obtainable at additional cost (in the case of Tenant, pro rata in proportion of Tenant’s rentable area to the total rentable area covered by such insurance); and if such other party does not so agree or the waiver shall not be obtainable, then
the provisions of this Section 12.5 shall be null and void as to the risks covered by such policy for so long as either such waiver cannot be obtained or the party in whose favor a waiver of subrogation is desired shall refuse to pay the
additional premium. If the release of either Landlord or Tenant, as set forth in the second sentence of this Section 12.5, shall contravene any law with respect to exculpatory agreements, the liability of the party in question shall be
deemed not released, but no action or rights shall be sought or enforced against such party unless and until all rights and remedies against the other’s insurer are exhausted and the other party shall be unable to collect such insurance
proceeds. 
 (B) The waiver of subrogation referred to in Section 12.5(A) above shall extend to the agents and employees of each
party (including, as to Landlord, the Manager), but only if and to the extent that such waiver can be obtained without additional charge (unless such party shall pay such charge). Nothing contained in this Section 12.5 shall be deemed to
relieve either party from any duty imposed elsewhere in this Lease to repair, restore and rebuild. 
 Section 12.6 Landlord shall
maintain and keep in full force and effect or cause to be maintained and kept in full force and effect, such insurance as the Lessor under any Superior Lease or the holder of any Mortgage shall require. If no Superior Lease or Mortgage is in effect,
then Landlord shall maintain and keep in full force and effect, with a reputable, good and solvent insurance company licensed to do business in the State of New York, the following insurance: (a) commercial general liability insurance
(including premises operation, bodily injury, personal injury, death, independent contractors, products and completed operations, broad form contractual liability and broad form property damage coverages) in a combined single limit amount of not
less than $5,000,000, arising from the conduct of Landlord, or omissions of Landlord, its agents, servants and contractors and (b) “all-risk” property insurance in amounts then customary for other commercial office buildings in the
vicinity of the Building in the City and County of New York. 
 ARTICLE 13 

DESTRUCTION BY FIRE OR OTHER CAUSE 

Section 13.1 If the Premises or any part thereof shall be damaged by fire or other casualty, Tenant shall give prompt written notice
thereof to Landlord. Landlord shall, subject to the provisions of Sections 13.2 and 13.3 below, proceed with commercially reasonable diligence, after receipt of the net proceeds of Landlord’s insurance (which Landlord shall use
commercially 

  
 36 

 
reasonable diligence to obtain), to repair or cause to be repaired such damage at its expense, but in no event shall Landlord be obligated to repair any damage to or to restore any of
Tenant’s leasehold improvements or Alterations, whether initially installed by Landlord or Tenant. Tenant, after receipt of the net proceeds of Tenant’s insurance (which Tenant shall use commercially reasonable diligence to obtain), shall
repair and restore in accordance with Article 6 and with reasonable dispatch all leasehold improvements and Alterations made by or for Tenant in the Premises. If the Premises, or any part thereof, shall be rendered untenantable by reason
of such damage, then the Fixed Rent and the Escalation Rent hereunder, or an amount thereof apportioned according to the area of the Premises so rendered untenantable (if less than the entire Premises shall be so rendered untenantable), shall be
abated for the period from the date of such damage to the date which is sixty days after the repair of such damage shall have been Substantially Completed. Notwithstanding any provisions contained in this Lease to the contrary, there shall be no
abatement with respect to any portion of the Premises which has not been so damaged and which is accessible and reasonably usable for the Permitted Use, provided that the continued operation of Tenant’s business in such portion of the Premises
is reasonably practicable (it being agreed that if Tenant is actually occupying such portion of the Premises for the conduct of its business, continued operation therein shall be deemed reasonably practicable). Landlord’s determination of the
date when the Premises are tenantable shall be controlling unless Tenant disputes the same by notice to Landlord given within 10 Business Days after such determination by Landlord in writing to Tenant, and pending resolution of such dispute, Tenant
shall commence the payment of the Fixed Rent and the Escalation Rent that had been abated, as of the date specified by Landlord. Tenant covenants and agrees to cooperate with Landlord and any Lessor or any Mortgagee in their efforts to collect
insurance proceeds (including rent insurance proceeds) payable to such parties. Landlord shall not be liable for any delay which may arise by reason of adjustment of insurance on the part of Landlord and/or Tenant, or any cause beyond the control of
Landlord or contractors employed by Landlord. 
 Section 13.2 Landlord shall not be liable for any inconvenience or annoyance to Tenant
or injury to the business of Tenant resulting in any way from damage from fire or other casualty or the repair thereof. Tenant understands that Landlord, in reliance upon Section 12.4, will not carry insurance of any kind on
Tenant’s Property, Tenant’s Alterations and on leasehold improvements, and that Landlord shall not be obligated to repair any damage thereto or replace the same. In the event of a partial or total destruction of the Premises, Tenant shall
as soon as practicable remove any and all of Tenant’s Property from the Premises or the portion thereof destroyed, as the case may be, and if Tenant does not promptly so remove Tenant’s Property, Landlord may discard the same after giving
Tenant fifteen (15) Business Days’ prior notice of the same or may remove Tenant’s Property to a public warehouse for deposit or retain the same in its own possession. 

Section 13.3 
 (A)
Notwithstanding anything to the contrary contained in Sections 13.1 and 13.2 above, in the event that: 
 (i) at least
one-third of the rentable area of the Building shall be damaged by fire or other casualty so that substantial alteration or reconstruction of the Building shall, in Landlord’s sole opinion, be required (whether or not the Premises shall have
been damaged by such fire or other casualty and without regard to the structural integrity of the Building); or 

  
 37 

 (ii) the Premises shall be totally or substantially damaged or shall be rendered wholly or
substantially untenantable (and at least 25,000 rentable square feet of the Building other than the Premises shall also have been totally or substantially damaged or shall be rendered wholly or substantially untenantable); or 

(iii) there shall be any damage to the Premises within the last year of the Term wherein the cost of repair exceeds an amount equal to four
(4) monthly installments of Fixed Rent, 
 then Landlord in the case of the circumstances described in clauses (i) through (iii) above, and
Tenant in the case of the circumstances described in clause (iii) above only, may, in such party’s sole and absolute discretion, terminate this Lease and the term and estate hereby granted, by notifying the other party in writing of such
termination within ninety (90) days after the date of such damage. In the event that such a notice of termination shall be given, then this Lease and the term and estate hereby granted shall expire as of the date of termination stated in said
notice with the same effect as if that were the Fixed Expiration Date, and the Fixed Rent and Escalation Rent hereunder shall be apportioned as of such date. 

(B) Notwithstanding anything to the contrary contained in this Section 13.3, Landlord shall deliver to Tenant within ninety
(90) days after the date of any casualty an estimate prepared by a reputable contractor selected by Landlord setting forth such contractor’s estimate as to the time reasonably required to repair such damage. If the period to repair set
forth in any such estimate exceeds eighteen (18) months from the date of such casualty, Tenant may elect to terminate this Lease by notice to Landlord given not later than thirty (30) days following Tenant’s receipt of such estimate.
If Tenant exercises such election, this Lease and the term and estate hereby granted shall expire as of the 60th day after notice of such election given by Tenant with the same effect as if that were the Fixed Expiration Date, and the Fixed Rent and
Escalation Rent hereunder (as abated in accordance with Section 13.1) shall be apportioned as of such date. If (i) Tenant shall not have exercised its right to terminate this Lease pursuant to this Section 13.3(B), but
the damage shall not have been repaired by the date set forth in such estimate (subject to extension due to Unavoidable Delay or Tenant Delay), or (ii) if the period to repair in such estimate is eighteen (18) months or less, but the
damage shall not have been repaired within eighteen (18) months after the date of the casualty (subject to extension due to Unavoidable Delay or Tenant Delay), Tenant may elect to terminate this Lease by notice to Landlord given not later than
thirty (30) days following the period set forth in such estimate for completion (where the same exceeds eighteen (18) months in the circumstances contemplated in clause (i) or following such eighteen (18) month period (where the
period set forth in such estimate for completion was eighteen (18) months or more, in the circumstances contemplated in clause (ii)), unless prior to the giving of such notice, Landlord shall have Substantially Completed such repair. 

Section 13.4 Except as may be provided in Section 12.5, nothing herein contained shall relieve either party from any
liability to the other party or to the other party’s insurers in connection with any damage to the Premises or the Building by fire or other casualty if the other party shall be legally liable in such respect. 

  
 38 

 Section 13.5 This Lease shall be considered an express agreement governing any case of
damage to or destruction of the Building or any part thereof by fire or other casualty, and Section 227 of the Real Property Law of the State of New York providing for such a contingency in the absence of express agreement and any other law of
like import now or hereafter in force, shall have no application in such case. 
 ARTICLE 14 

EMINENT DOMAIN 

Section 14.1 If the whole of the Real Property, the Building or the Premises is acquired or condemned for any public or quasi-public use
or purpose, this Lease and the Term shall end as of the date of the vesting of title with the same effect as if said date were the Fixed Expiration Date. If only a part of the Real Property and not the entire Premises is so acquired or condemned
then, (1) except as hereinafter provided in this Section 14.1, this Lease and the Term shall continue in effect but, if a part of the Premises is included in the part of the Real Property so acquired or condemned, from and after the
date of the vesting of title, the Fixed Rent and Tenant’s Share shall be reduced in the proportion which the area of the part of the Premises so acquired or condemned bears to the total area of the Premises immediately prior to such acquisition
or condemnation; (2) Landlord, at Landlord’s option, may give to Tenant, within sixty (60) days next following the date upon which Landlord receives notice of vesting of title, a sixty (60) day notice of termination of this
Lease; and (3) if the part of the Real Property so acquired or condemned contains more than thirty (30%) percent of the total area of the Premises immediately prior to such acquisition or condemnation, or if, by reason of such acquisition
or condemnation, Tenant no longer has reasonable access to the Premises, Tenant, at Tenant’s option, may give to Landlord, within sixty (60) days next following the date upon which Tenant receives notice of vesting of title, a sixty
(60) day notice of termination of this Lease. If any such sixty (60) day notice of termination is given, by Landlord or Tenant, this Lease and the Term shall come to an end and expire upon the expiration of said sixty (60) days with
the same effect as if the date of expiration of said sixty (60) days were the Fixed Expiration Date. If a part of the Premises is so acquired or condemned and this Lease and the Term are not terminated pursuant to the foregoing provisions of
this Section 14.1, Landlord, at Landlord’s cost and expense, shall restore that part of the Premises not so acquired or condemned to a self-contained rental unit, exclusive of Tenant’s Alterations, Tenant’s leasehold
improvements and Tenant’s Property. In the event of any termination of this Lease and the Term pursuant to the provisions of this Section 14.1, the Fixed Rent shall be apportioned as of the date of sooner termination and any prepaid
portion of the Fixed Rent or Escalation Rent for any period after such date shall be refunded by Landlord to Tenant. 
 Section 14.2 In
the event of any such acquisition or condemnation of all or any part of the Real Property, Landlord shall be entitled to receive the entire award for any such acquisition or condemnation (subject to the last sentence of this
Section 14.2). Tenant shall have no claim against Landlord or the condemning authority for the value of any unexpired portion of the Term and Tenant hereby expressly assigns to Landlord all of its right in and to any such award. Nothing
contained in this Section 14.2 shall be deemed to prevent Tenant from making a separate claim in any condemnation proceedings for the value of any Tenant’s Property included in such taking, and for any moving expenses, so long as
Landlord’s award is not reduced thereby. 

  
 39 

 Section 14.3 If the whole or any part of the Premises is acquired or condemned temporarily
(i.e., for not more than twelve (12) consecutive months) during the Term for any public or quasi-public use or purpose, Tenant shall give prompt notice thereof to Landlord and the Term shall not be reduced or affected in any way and Tenant
shall continue to pay in full all items of Rental payable by Tenant hereunder without reduction or abatement, and Tenant shall be entitled to receive for itself any award or payments for such use, provided, however, that if the acquisition or
condemnation is for a period extending beyond the Term, such award or payment shall be apportioned between Landlord and Tenant as of the Expiration Date. 

ARTICLE 15 
 ASSIGNMENT,
SUBLETTING, MORTGAGE, ETC. 
 Section 15.1 Except as otherwise provided in this Article 15, Tenant shall not (a) assign
this Lease (whether by operation of law, transfers of interests in Tenant or otherwise); or (b) mortgage or encumber Tenant’s interest in this Lease, in whole or in part; or (c) sublet, or permit the subletting of, the Premises or any
part thereof; or (d) permit the Premises or any part thereof to be occupied or used for desk space, mailing privileges or otherwise by any person other than Tenant. Tenant shall not advertise or authorize a broker to advertise for a subtenant
or assignee, without in each instance, obtaining the prior written consent of Landlord to the form of such advertisement, which consent shall not be unreasonably withheld, conditioned or delayed. 

Section 15.2 If Tenant’s interest in this Lease shall be assigned in violation of the provisions of this Article 15, such
assignment shall be invalid and of no force and effect against Landlord; provided, however, that Landlord may collect an amount equal to the then Fixed Rent plus any other item of Rental from the assignee as a fee for its use and occupancy. If the
Premises or any part thereof are sublet to, or occupied by, or used by, any person other than Tenant, whether or not in violation of this Article 15, Landlord, after default by Tenant under this Lease, may collect any item of Rental or other
sums paid by the subtenant, user or occupant as a fee for its use and occupancy, and shall apply the net amount collected to the Fixed Rent and the items of Rental reserved in this Lease. No such assignment, subletting, occupancy, or use, whether
with or without Landlord’s prior consent, nor any such collection or application of Rental or fee for use and occupancy, shall be deemed a waiver by Landlord of any term, covenant or condition of this Lease or the acceptance by Landlord of such
assignee, subtenant, occupant or user as Tenant hereunder, nor shall the same, in any circumstances, relieve Tenant of any of its obligations under this Lease. The consent by Landlord to any assignment, subletting, occupancy or use shall not relieve
Tenant from its obligation to obtain the express prior consent of Landlord to any further assignment, subletting, occupancy or use. Any Person to which this Lease is assigned with Landlord’s consent shall be deemed without more to have assumed
all of the obligations arising under this Lease from and after the date of such assignment and shall execute and deliver to Landlord, upon demand, an instrument in commercially reasonable form confirming such assumption. Notwithstanding and
subsequent to any assignment, Tenant’s primary liability hereunder shall continue notwithstanding (a) any subsequent amendment hereof, or (b) Landlord’s forbearance in enforcing against Tenant any obligation or liability, without
notice to Tenant, to each of which Tenant hereby consents in advance. If any such amendment operates to increase the obligations of Tenant under this Lease, the liability under this Section 15.2 of the assigning Tenant shall continue to
be no greater than if such amendment had not been made (unless such party shall have expressly consented in writing to such amendment). 

  
 40 

 Section 15.3 

(A) For purposes of this Article 15, (i) the transfer of a majority of the issued and outstanding capital stock of any corporate
tenant, or of a corporate subtenant, or the transfer of a majority of the total interest in any partnership tenant or subtenant, or the transfer of control in any general or limited liability partnership tenant or subtenant, or the transfer of a
majority of the issued and outstanding membership interests in a limited liability company tenant or subtenant, however accomplished, whether in a single transaction or in a series of related or unrelated transactions, involving the tenant,
subtenant and/or its parent (including, without limitation, and by way of example only, the transfer of a majority of the outstanding capital stock of a company, which company owns 100% of a second tier company, which in turn owns 51% of the
outstanding capital stock of a corporate tenant hereunder), shall be deemed an assignment of this Lease, or of such sublease, as the case may be, except that the transfer of the outstanding capital stock of any corporate tenant, subtenant or parent,
shall be deemed not to include the sale of such stock by persons or parties, other than those deemed “affiliates” of Tenant within the meaning of Rule 144 promulgated under the Securities Act of 1933, as amended, through the
“over-the-counter market” or through any recognized stock exchange, (ii) any increase in the amount of issued and/or outstanding capital stock of any corporate tenant, or of a corporate subtenant, or such tenant’s or
subtenant’s parent, or of the issued and outstanding membership interests in a limited liability company tenant or subtenant, or such tenant’s or subtenant’s parent, and/or the creation of one or more additional classes of capital
stock of any corporate tenant or any corporate subtenant, or such tenant’s or subtenant’s parent, in a single transaction or a series of related or unrelated transactions involving the tenant, subtenant and/or its parent, resulting in a
change in the legal or beneficial ownership of such tenant, subtenant or parent so that the shareholders or members of such tenant, subtenant or parent existing immediately prior to such transaction or series of transactions shall no longer own a
majority of the issued and outstanding capital stock or membership interests of such entity, shall be deemed an assignment of this Lease, (iii) an agreement by any other person or entity, directly or indirectly, to assume Tenant’s
obligations under this Lease shall be deemed an assignment, (iv) any person or legal representative of Tenant, to whom Tenant’s interest under this Lease passes by operation of law, or otherwise, shall be bound by the provisions of this
Article 15 and (v) a modification, amendment or extension of a sublease shall be deemed a sublease. Tenant agrees to furnish to Landlord on request at any time such information and assurances as Landlord may reasonably request that
neither Tenant, nor any previously permitted subtenant, has violated the provisions of this Article 15. 
 (B) The provisions of
clauses (a), (c) and (d) of Section 15.1 and Section 15.4 shall not apply to (and Landlord’s consent shall not be required for) (i) a change in ownership of Tenant as a result of a merger, consolidation or
reorganization or the sale of substantially all of Tenant’s assets (provided such merger, consolidation, reorganization or transfer of assets is for a good business purpose and not principally for the purpose of transferring the leasehold
estate created by this Lease, and provided further, that the assignee has a net worth at least equal to or in excess of ninety-five (95%) percent of the net worth of Tenant as of the date of this Lease; (ii) the sale, exchange, issuance or
other transfer of Tenant’s stock on a national stock exchange; or (iii) the assignment of this Lease or sublease of all or any portion of the Premises to, or the use of 

  
 41 

 
the Premises by, an entity which controls, is controlled by or is under the common control of Tenant. Tenant shall notify Landlord before any such transaction is consummated, unless such prior
notice violates any securities laws or regulatory requirements applicable to Tenant, in which event Tenant shall notify Landlord promptly after Tenant is permitted to do so. 

(C) The term “control” as used in this Lease (i) in the case of a corporation shall mean ownership of more than fifty
(50%) percent of the outstanding capital stock of that corporation, (ii) in the case of a general or limited liability partnership, shall mean ownership of more than fifty (50%) percent of the general partnership or membership
interests of the partnership, (iii) in the case of a limited partnership, shall mean ownership of more than fifty (50%) percent of the general partnership interests of such limited partnership, and (iv) in the case of a limited
liability company, shall mean ownership of more than fifty (50%) percent of the membership interests of such limited liability company. 

Section 15.4 
 (A) If
Landlord shall not exercise its rights pursuant to paragraph (B)(x) or (y) of this Section 15.4, Landlord shall not unreasonably withhold, condition or delay its consent to a proposed subletting of the Premises, or an assignment of
this Lease (and shall provide Tenant with Landlord’s reasons for any disapproval), provided that in each such instance, the following requirements shall have been satisfied (if Tenant proposes a partial sublet, references in this
Section 15.4 to the Premises shall, unless the context otherwise requires, refer to such portion): 
 (1) in the case of a
proposed subletting, the listing or advertising for subletting of the Premises shall not have included a proposed rental rate, provided, however, that Tenant may quote in writing directly to prospective subtenants the proposed rental rate; 

(2) no Event of Default shall have occurred and be continuing; 

(3) the proposed subtenant or assignee shall have a financial standing adequate in Landlord’s reasonable judgment to satisfy its
obligations under the sublease or this Lease, as applicable, be engaged in a business, and propose to use the Premises in a manner in keeping with the standards in such respects of the other tenancies in the Building; 

(4) provided that Landlord then has comparable space available for lease in the Building or reasonably expects to have comparable space
available for lease in the Building within the following six (6) month period, the proposed subtenant or assignee shall not be (x) a Person with whom Landlord is then actively negotiating the leasing of space in the Building, which shall
be evidenced by the issuance of a proposed term sheet or offer by Landlord or its agent or by the proposed subtenant or assignee or its broker; or (y) a tenant in or occupant of the Building or any Person that, directly or indirectly, is
controlled by, controls or is under common control with any such tenant or occupant; 
 (5) intentionally omitted; 

(6) any subletting shall be expressly subject to all of the terms, covenants, conditions and obligations on Tenant’s part to be observed
and performed under this Lease and any assignment or subletting shall be subject to the further condition and restriction that this Lease or the sublease shall not be further assigned, encumbered or otherwise transferred

  
 42 

 
or the subleased premises further sublet by the subtenant in whole or in part, or any part thereof suffered or permitted by the assignee or subtenant to be used or occupied by others, without the
prior written consent of Landlord in each instance, which consent shall be governed by all of the applicable provisions of this Article 15, and if Landlord shall consent to any further subletting by the subtenant or the assignment of the
sublease, Sections 15.5 and 15.6 of this Lease shall apply to any such transactions as if the further subletting or assignment of the sublease were a proposed subletting or assignment being made by Tenant under this Lease so that
Landlord shall be entitled to receive all amounts described in such Sections; 
 (7) the subleased premises shall be regular in shape and
at no time shall there be more than two (2) occupants with separately demised space for each full floor, including Tenant, in the Premises, all of whom shall have direct access through existing public corridors to elevators, fire stairs and
core rest rooms. 
 (8) Tenant shall reimburse Landlord on demand for any reasonable and actual out-of-pocket costs that are incurred by
Landlord in connection with said assignment or sublease, including, without limitation, any reasonable and actual out-of-pocket processing fees, attorneys’ fees and disbursements, and the reasonable and actual out-of-pocket costs of making
investigations as to the acceptability of the proposed assignee or subtenant; 
 (9) any sublease shall expressly provide that in the event
of termination, re-entry or dispossession of Tenant by Landlord under this Lease, Landlord may, at its option, take over all of the right, title and interest of Tenant as sublessor under such sublease, and such subtenant shall, at Landlord’s
option, attorn to Landlord pursuant to the then executory provisions of such sublease, except that Landlord shall not be (i) liable for any previous act or omission of Tenant under such sublease, (ii) subject to any offset that theretofore
accrued to such subtenant against Tenant, (iii) bound by any previous modification of such sublease or by any previous prepayment of more than one month’s rent unless previously approved by Landlord, (iv) bound by any covenant to
undertake or complete or make payment to or on behalf of a subtenant with respect to any construction of the Premises or any portion thereof demised by such sublease and (v) bound by any obligations to make any other payment to or on behalf of
the subtenant, except for services, repairs, maintenance and restoration provided for under the sublease to be performed after the date of such termination, reentry or dispossession by Landlord under this Lease and which Landlord is required to
perform hereunder with respect to the subleased space at Landlord’s expense; 
 (10) The nature of the occupancy of the proposed
assignee or subtenant will not result in (x) additional density of employees or increased traffic or (y) make additional demands on the Building Systems or (z) present a greater (by more than a de minimis amount) security risk
to the Building than is presented by Tenant; 
 (11) The nature of the occupancy, the use and the manner of use of the Premises by the
proposed subtenant or assignee shall not impose on Landlord any requirements of the ADA in excess of those requirements imposed on Landlord in the absence of such proposed subtenant or assignee or such occupancy, use or manner of use, unless such
proposed subtenant or assignee shall have agreed to comply with each of such excess requirements; and 
 (12) Landlord and Tenant shall
have agreed on the computation required under Section 15.5 or Section 15.6, as applicable. 

  
 43 

 (B) Upon obtaining a proposed assignee or subtenant, upon terms satisfactory to Tenant, Tenant
shall submit to Landlord in writing (the following documents and information being collectively referred to as the “Sublease or Assignment Statement”): (i) the name and business address of the proposed assignee or subtenant;
(ii) the nature and character of the business and credit of the proposed assignee or subtenant; (iii) an original counterpart of the proposed assignment or sublease and all related agreements, the effective or commencement date of which
shall be at least thirty (30) days after the date Tenant’s notice to Landlord is given, along with Tenant’s and the subtenant’s (or assignee’s) affidavit that such sublease or assignment instrument is the true and complete
statement of the subletting or assignment and reflects all sums and other consideration passing between the parties to the sublease or assignment and all reports, returns, transferor and transferee questionnaires and other documents required to be
filed under Article 31 of the New York State Tax Law and under Chapter 21 of the New York City Administrative Code; (iv) current financial information with respect to the proposed assignee or subtenant, including, without limitation, its
most recent financial statements, certified by an independent certified public accountant (“CPA”) if such financial statements are certified by a CPA (or, if not, certified by the chief financial officer of the proposed assignee or
subtenant as being true and correct) and (v) any other information that Landlord may reasonably request. Landlord shall have the following rights, exercisable within thirty (30) days after Landlord’s receipt of the Sublease or
Assignment Statement (including any additional information reasonably requested by Landlord): (x) in the case of an assignment of this Lease or a subletting of the entire Premises, to sublet (in its own name or that of its designee) the entire
Premises from Tenant on the terms and conditions set forth in paragraph (C) of this Section 15.4, or to terminate this Lease or to take an assignment of this Lease from Tenant or (y) in the case of a subletting of a portion of
the Premises for a term ending within three years of the Expiration Date, to sublet (in its own name or that of its designee) such portion of the Premises (the entire Premises sublet by Landlord (or its designee) pursuant to clause (x) or such
portion of the Premises sublet by Landlord (or its designee) pursuant to this clause (y) being referred to as the “Recapture Space”) from Tenant on the terms and conditions set forth in paragraph (C) of this
Section 15.4, or to terminate this Lease with respect only to the Recapture Space or (z) to approve or disapprove the proposed assignment or sublease in accordance with the provisions of Section 15.4 (A). If Landlord
shall fail to notify Tenant within said thirty (30) day period of Landlord’s intention to exercise its rights pursuant to clauses (x) or (y) of this Section 15.4(B), or to have approved or disapproved the transaction,
Landlord shall be deemed to have not exercised its right to sublet or terminate or take an assignment of this Lease and shall be deemed to have approved such transaction, provided that Tenant shall have sent Landlord a second request for
approval following such thirty (30) day period containing the following language in eighteen-point print: “THIS IS A SECOND REQUEST FOR APPROVAL OF THE PROPOSED [ASSIGNMENT] OR [SUBLETTING]. IF LANDLORD DOES NOT RESPOND TO THIS REQUEST
WITHIN FIVE (5) BUSINESS DAYS, LANDLORD’S APPROVAL SHALL BE DEEMED GRANTED PURSUANT TO THE PROVISIONS OF SECTION 15.4 OF THE LEASE” and Landlord shall have failed to respond within such time period. If pursuant to the exercise of any
of Landlord’s options pursuant to this Section 15.4, this Lease is terminated as to only a portion of the Premises, then the Fixed Rent and Escalation Rent shall be adjusted in proportion to the portion of the Premises affected by
such termination. 

  
 44 

 (C) (1) If Landlord shall exercise its option to sublet the Recapture Space, then,
notwithstanding the terms contained in the Sublease or Assignment Statement, such sublease (a “Recapture Sublease”) to Landlord or its designee as subtenant (the “Recapture Subtenant”) or assignee shall: 

(a) be at a rate, at all times throughout the term of the Recapture Sublease, equal to (if Tenant had proposed to sublet the Premises) the
lower of (i) the rate then payable by Tenant under this Lease and (ii) the rate set forth in the Sublease or Assignment Statement; 

(b) otherwise be upon the same terms and conditions as those contained in the Sublease or Assignment Statement (other than, in the case of an
assignment, payment of consideration therefor to Tenant) and (except as modified by the Sublease or Assignment Statement) the terms and conditions contained in this Lease, except such as are irrelevant or inapplicable and except as otherwise
expressly set forth to the contrary in this paragraph (C); 
 (c) give the Recapture Subtenant the unqualified and unrestricted right,
without Tenant’s permission, to assign such sublease and to further sublet the Recapture Space or any part thereof and to make any and all changes, alterations, and improvements in and to the Recapture Space; 

(d) provide in substance that any such changes, alterations, and improvements made in the Recapture Space may be removed, in whole or in
part, prior to or upon the expiration or other termination of the Recapture Sublease provided that any material damage and injury caused thereby shall be repaired, and provided further that, if the term of the sublease shall expire more than
one (1) year prior to the Expiration Date (as the same may have been extended), if required by Tenant, the Recapture Subtenant shall remove any or all of such changes, alterations and improvements prior to or upon the expiration or other
termination of the Recapture Sublease and any material damage and injury caused thereby shall be repaired by the Recapture Subtenant; 

(e) provide that (i) the parties to such Recapture Sublease expressly negate any intention that any estate created under the Recapture
Sublease be merged with any estate held by either of said parties, (ii) prior to the commencement of the term of the Recapture Sublease, Tenant, at its expense, shall make such alterations as may be required or reasonably deemed necessary by
the Recapture Subtenant to physically separate the Recapture Space from the balance of the Premises and to provide appropriate means of access thereto and to the public portions of the balance of the floor such as toilets, janitor’s closets,
telephone and electrical closets, fire stairs, elevator lobbies, etc., and (iii) at the expiration of the term of such Recapture Sublease, the Recapture Subtenant shall quit and surrender to Tenant the Recapture Space, vacant, broom clean, in
good order and condition, ordinary wear and tear excepted, and the Recapture Subtenant shall remove any changes, alterations and improvements made by the Recapture Subtenant in the Recapture Space to the extent required pursuant to
Section 15.4(C)(1)(d) (provided, however, that in no event shall Tenant be liable hereunder for the removal of any changes, alterations, and improvements made to the Recapture Space by the Recapture Subtenant or for
anything done in or to the Recapture Space during the Recapture Subtenant’s occupancy thereof); and 
 (f) provide that the Recapture
Subtenant or occupant shall use and occupy the Recapture Space for any purpose approved by Landlord (without regard to any limitation set forth in the Sublease or Assignment Statement). 

  
 45 

 (2) Until the termination of a Recapture Sublease, performance by Recapture Subtenant under a
Recapture Sublease shall be deemed performance by Tenant of any similar obligation under this Lease and Tenant shall not be liable for any default under this Lease or deemed to be in default hereunder if such default is occasioned by or arises from
any act or omission of Recapture Subtenant under the Recapture Sublease or is occasioned by or arises from any act or omission of any occupant under the Recapture Sublease. 

(3) If Recapture Subtenant is unable to give Tenant possession of the Recapture Space at the expiration of the term of the Recapture Sublease
by reason of the holding over or retention of possession of any tenant or other occupant, then (w) until the date upon which Recapture Subtenant gives Tenant possession of such Recapture Space free of occupancies, Recapture Subtenant shall
continue to pay all charges previously payable, and comply with all other obligations under the Recapture Sublease and the provisions of Section 15.4(C)(2) shall continue to apply, (x) neither the Expiration Date nor the validity of
this Lease shall be affected, (y) Tenant waives any rights under Section 223-a of the Real Property Law of New York, or any successor statute of similar import, to rescind this Lease and further waives the right to recover any damages from
Landlord or Recapture Subtenant that may result from the failure of Landlord to deliver possession of the Recapture Space at the end of the term of the Recapture Sublease, and (z) Recapture Subtenant, at Recapture Subtenant’s expense,
shall use its reasonable efforts to deliver possession of such Recapture Space to Tenant and in connection therewith, if necessary, shall institute and diligently and in good faith prosecute holdover and any other appropriate proceeding against the
occupant of such Recapture Space. Notwithstanding the foregoing, if Recapture Subtenant is unable to give Tenant possession of the Recapture Space at the Expiration Date, then provided that Tenant has complied with its obligation to surrender the
remainder of the Premises, if any, in accordance with the terms of this Lease, this Lease shall end as of the Expiration Date and Tenant shall not be liable for any costs incurred nor shall Tenant have any further obligations with respect to the
Recapture Space, other than any obligations under this Lease which accrued prior to the commencement of the term of the Recapture Sublease and which by their terms survive the expiration or earlier termination of this Lease. 

(4) The failure by Landlord to exercise its option under Section 15.4(B)(x) or (y) with respect to any subletting or
assignment shall not be deemed a waiver of such option with respect to any extension of such subletting or assignment except for extensions pursuant to the terms contained in the Sublease or any subsequent subletting or assignment. 

Section 15.5 If Tenant sublets any portion of the Premises to a Person in a transaction for which Landlord’s consent is required,
Landlord shall be entitled to and Tenant shall pay to Landlord, as Additional Rent (the “Sublease Additional Rent”), a sum equal to fifty (50%) percent of any rents, additional charges and other consideration payable under the
sublease to Tenant by the subtenant in excess of the Fixed Rent and Escalation Rent accruing during the term of the sublease in respect of the subleased space (at the rate per square foot payable by Tenant under this Lease) pursuant to the terms of
this Lease (including, but not limited to, sums paid for the sale or rental of Tenant’s Property less, in the case of a sale thereof, the then net unamortized or undepreciated cost thereof determined on the basis of Tenant’s federal
income 

  
 46 

 
tax or federal information returns) after first deducting from such rents, additional charges and other consideration the actual out-of-pocket expenses reasonably incurred by Tenant in connection
with such sublease on account of brokerage commissions, advertising expenses, legal fees, customary rent concessions, work contributions and the cost of work performed by Tenant to prepare the Premises for the subtenant’s occupancy, all
amortized on a straight-line basis over the term of the sublease. Such Sublease Additional Rent shall be payable as and when received by Tenant. 

Section 15.6 If Tenant shall assign this Lease to a Person in a transaction for which Landlord’s consent is required, Landlord shall
be entitled to and Tenant shall pay to Landlord, as Additional Rent, an amount equal to fifty (50%) percent of all sums and other consideration paid to Tenant by the assignee for or by reason of such assignment (including, but not limited to,
sums paid for the sale or rental of Tenant’s Property less, in the case of a sale thereof, the then net unamortized or undepreciated cost thereof determined on the basis of Tenant’s federal income tax or federal information returns)
and after first deducting from such sums and other consideration the actual out-of-pocket expenses reasonably incurred by Tenant in connection with such assignment on account of brokerage commissions, advertising expenses, legal fees, customary rent
concessions, work contributions and the cost of work performed by Tenant to prepare the Premises for the assignee’s occupancy. Such Additional Rent shall be payable as and when received by Tenant from the assignee. 

Section 15.7 Landlord shall have no liability for brokerage commissions incurred with respect to any assignment of this Lease or any
subletting of all or any part of the Premises by or on behalf of Tenant. Tenant shall pay, and shall indemnify and hold Landlord harmless from and against, any and all cost, expense (including reasonable attorneys’ fees and disbursements) and
liability in connection with any compensation, commissions or charges claimed by any broker or agent with respect to any such assignment or subletting. 

ARTICLE 16 
 ACCESS TO PREMISES

 Section 16.1 
 (A)
Tenant shall permit Landlord, Landlord’s agents and public utilities servicing the Building to erect, use and maintain concealed ducts, pipes and conduits in and through the Premises, provided same (i) do not unreasonably interfere with
Tenant’s use or occupancy of the Premises, (ii) do not diminish the usable area of the Premises by more than a de minimis amount, and (iii) comply with Section 16.1(C) below. Landlord or Landlord’s agents shall
have the right to enter the Premises at all reasonable times upon (except in case of emergency) reasonable prior notice, which notice may be oral, (I) to examine the same, (II) to show the same to prospective purchasers, Mortgagees or Lessors
or, within the last twelve (12) months of the Term, to prospective tenants of space in the Building, or (III) to make such repairs, alterations, improvements or additions (a) as Landlord may deem necessary or desirable to the Premises or
to any other portion of the Building, or (b) which Landlord may elect to perform at least ten (10) Business Days after notice (except in an emergency when no notice shall be required) following Tenant’s failure to make repairs or
perform any work which Tenant is obligated to make or perform under this Lease, or (c) for the purpose of complying with 

  
 47 

 
Requirements, and Landlord shall be allowed to take all material into (but not store) and upon the Premises that may be required therefor without the same constituting an eviction or constructive
eviction of Tenant in whole or in part and the Fixed Rent (and any other item of Rental) shall in no respect abate or be reduced by reason of said repairs, alterations, improvements or additions, wherever located, or while the same are being made,
by reason of loss or interruption of business of Tenant, or otherwise. Landlord shall make commercially reasonable efforts to minimize interference with Tenant’s use of the Premises as a result of any such entry and shall (x) promptly
repair any damage caused to the Premises by such work, alterations, improvements or additions, or by the acts of any prospective tenants, purchasers, Mortgagees or Lessors accompanying Landlord into the Premises pursuant to clause (II) above, and
(y) indemnify and hold harmless Tenant from and against any liability caused by acts in the Premises of any prospective tenants, purchasers, Mortgagees or Lessors accompanying Landlord into the Premises pursuant to clause (II) above. 

(B) Any work performed or installations made pursuant to this Article 16 shall be made with reasonable diligence and otherwise pursuant
to Section 7.3. 
 (C) Any pipes, ducts, or conduits installed in or through the Premises pursuant to this Article 16
shall, if reasonably practicable, either be concealed behind, beneath or within partitioning, columns, ceilings or floors located or to be located in the Premises, or completely furred at points immediately adjacent to partitioning, columns or
ceilings located or to be located in the Premises. 
 Section 16.2 If Tenant is not present when for any reason entry into the Premises
may be necessary or permissible in the case of emergency (or for normal janitorial services performed during non-Operating Hours), Landlord or Landlord’s agents may enter the same without rendering Landlord or such agents liable therefor (if
during such entry Landlord or Landlord’s agents accord reasonable care to Tenant’s Property), and without in any manner affecting this Lease. 

Section 16.3 Landlord also shall have the right at any time, without the same constituting an actual or constructive eviction and without
incurring any liability to Tenant therefor, (i) to change the arrangement or location of public entrances or passageways; public doors, doorways, and corridors; public elevators; public stairs; public toilets; or other public parts of the
Building, provided any such change does not unreasonably interfere with, or deprive Tenant of access to, the Building or the Premises; (ii) to put so-called “solar film” or other energy-saving installations on the inside and
outside of the windows; and (iii) to change the name, number or designation by which the Building is commonly known. All parts (except surfaces facing the interior of the Premises) of all walls, windows and doors bounding the Premises
(including exterior Building walls, exterior core corridor walls, exterior doors and entrances), all balconies, terraces and roofs adjacent to the Premises, all space in or adjacent to the Premises used for shafts, stacks, stairways, chutes, pipes,
conduits, ducts, fan rooms, heating, air cooling, plumbing and other mechanical facilities, service closets and other Building facilities are not part of the Premises, and Landlord shall have the use thereof, as well as access thereto through the
Premises for the purposes of inspection, operation, maintenance, alteration and repair, subject to Landlord’s compliance with the provisions of this Article 16. 

  
 48 

 ARTICLE 17 

CERTIFICATE OF OCCUPANCY 

Section 17.1 Landlord has obtained a temporary certificate of occupancy for the Building (“TCO”), a copy of which is
annexed hereto as Schedule K, and Landlord shall maintain and renew, as necessary, such TCO until such time as a permanent certificate of occupancy is issued for the Building by the New York City Department of Buildings. 

Section 17.2 Tenant shall not at any time use or occupy the Premises in violation of any TCO or permanent certificate of occupancy issued
for the Premises or for the Building. In the event that any Government Authority hereafter contends or declares by notice, violation, order or in any other manner whatsoever that the Premises are used for a purpose that is a violation of such
certificate of occupancy, Tenant shall, upon three (3) Business Days’ written notice from Landlord or any Government Authority, immediately discontinue such use of the Premises; provided, however, that nothing herein shall prevent Tenant
from contesting such violation pursuant to and in accordance with the provisions of Section 9.5. 
 ARTICLE 18 

DEFAULT 

Section 18.1 Each of the following events shall be an “Event of Default” under this Lease: 

(A) if Tenant shall on any occasion default in the payment when due of any installment of Fixed Rent or in the payment when due of any other
item of Rental and such default shall continue for five (5) Business Days after Landlord shall have given Tenant written notice of such default; or 

(B) if the Premises shall be abandoned by Tenant; or 

(C) if Tenant’s interest in this Lease shall devolve upon or pass to any person, whether by operation of law or otherwise, except as
expressly permitted under Article 15 hereof; or 
 (D) (1) if Tenant shall not, or shall be unable to, or shall admit in writing
Tenant’s inability to, as to any obligation, pay Tenant’s debts as they become due; or 
 (2) if Tenant shall commence or
institute any case, proceeding or other action (a) seeking to adjudicate it a bankrupt or insolvent, or seeking reorganization, arrangement, adjustment, winding-up, liquidation, dissolution, composition or other relief with respect to Tenant or
Tenant’s debts under any existing or future law of any jurisdiction, domestic or foreign, relating to bankruptcy, insolvency, reorganization or relief of debtors, or (b) seeking appointment of a receiver, trustee, custodian or other
similar official for it or for all or any substantial part of its property; or 
 (3) if Tenant shall make a general assignment for the
benefit of creditors; or 

  
 49 

 (4) if any case, proceeding or other action shall be commenced or instituted against Tenant
(a) seeking to adjudicate Tenant a bankrupt or insolvent, or seeking reorganization, arrangement, adjustment, winding-up, liquidation, dissolution, composition or other relief with respect to Tenant or Tenant’s debts under any existing or
future law of any jurisdiction, domestic or foreign, relating to bankruptcy, insolvency, reorganization or relief of debtors, or (b) seeking appointment of a receiver, trustee, custodian or other similar official for Tenant or for all or any
substantial part of Tenant’s property, which either (i) results in any such entry of an order for relief, adjudication of bankruptcy or insolvency or such an appointment or the issuance or entry of any other order having a similar effect
or (ii) remains undismissed for a period of ninety (90) days; or 
 (5) if a trustee, receiver or other custodian shall be
appointed for any substantial part of the assets of Tenant which appointment is not vacated or effectively stayed within ninety (90) days; or 

(6) if Tenant rejects this Lease in connection with any action or proceeding under the Bankruptcy Code; or 

(E) if Tenant shall default in the observance or performance of any other term, covenant or condition of this Lease on Tenant’s part to
be observed or performed and Tenant shall fail to remedy such default within 30 days after notice by Landlord to Tenant of such default, or if such default is of such a nature that it cannot with due diligence be completely remedied within said
period of 30 days and the continuation of which for the period required for cure will not subject Landlord to the risk of criminal liability or termination of any Superior Lease or foreclosure of any Mortgage, if Tenant shall not, (i) within
said 30 day period advise Landlord of Tenant’s intention duly to institute all steps necessary to remedy such situation, (ii) duly institute within said 30 day period, and thereafter diligently and continuously prosecute to completion all
steps necessary to remedy the same and (iii) complete such remedy within such time after the date of the giving of said notice by Landlord as shall reasonably be necessary. 

Section 18.2 If an Event of Default shall occur, Landlord may, at any time thereafter (unless such Event of Default has been remedied or
waived by Landlord), at Landlord’s option, give written notice to Tenant stating that this Lease and the Term shall expire and terminate on the date specified in such notice, which date shall not be less than five (5) days after the giving
of such notice, whereupon this Lease and the Term and all rights of Tenant under this Lease shall automatically expire and terminate as if the date specified in the notice given pursuant to this Section 18.2 were the Fixed Expiration
Date and Tenant immediately shall quit and surrender the Premises, but Tenant shall remain liable for damages as provided herein or pursuant to law. Anything contained herein to the contrary notwithstanding, if such termination shall be stayed by
order of any court having jurisdiction over any proceeding described in Section 18.1(F), or by federal or state statute, then, following the expiration of any such stay, or if the trustee appointed in any such proceeding, Tenant or
Tenant as debtor-in-possession fails to assume Tenant’s obligations under this Lease within the period prescribed therefor by law or within one hundred twenty (120) days after entry of the order for relief or as may be allowed by the
court, or if said trustee, Tenant or Tenant as debtor-in-possession shall fail to provide adequate protection of Landlord’s right, title and interest in and to the Premises or adequate assurance of the complete and continuous future performance
of Tenant’s obligations under this Lease, Landlord, to the extent permitted by law or by leave of the court having jurisdiction over such proceeding, shall 

  
 50 

 
have the right, at its election, to terminate this Lease on five (5) days’ notice to Tenant, Tenant as debtor-in-possession or said trustee and upon the expiration of said five
(5) day period this Lease shall cease and expire as aforesaid and Tenant, Tenant as debtor-in-possession or said trustee shall immediately quit and surrender the Premises as aforesaid. 

Section 18.3 If, at any time, (i) Tenant shall consist of two (2) or more persons, or (ii) Tenant’s obligations under
this Lease shall have been guaranteed by any person other than Tenant, or (iii) Tenant’s interest in this Lease has been assigned, the word “Tenant” as used in Section 18.1(E), shall be deemed to mean any one
or more of the persons primarily or secondarily liable for Tenant’s obligations under this Lease. Any monies received by Landlord from or on behalf of Tenant during the pendency of any proceeding of the types referred to in
Section 18.1(E) shall be deemed paid as compensation for the use and occupancy of the Premises and the acceptance of any such compensation by Landlord shall not be deemed an acceptance of Rental or a waiver on the part of Landlord of any
rights under Section 18.2. 
 ARTICLE 19 

REMEDIES AND DAMAGES 

Section 19.1 
 (A) If any
Event of Default shall occur, or this Lease and the Term shall expire and come to an end as provided in Article 18: 
 (1)
Tenant shall quit and peacefully surrender the Premises to Landlord, and Landlord and its agents may immediately, or at any time after such Event of Default or after the date upon which this Lease and the Term shall expire and come to an end,
re-enter the Premises or any part thereof, either by summary proceedings, or by any other applicable legal action or legal proceeding (without being liable to indictment, prosecution or damages therefor), but excluding by force, and may repossess
the Premises and dispossess Tenant and any other persons from the Premises by summary proceedings or otherwise (excluding by force) and remove any and all of their property and effects from the Premises (and Tenant shall remain liable for damages as
provided herein or pursuant to law); and 
 (2) Landlord, at Landlord’s option, may relet the whole or any part or parts of the
Premises from time to time, either in the name of Landlord or otherwise, to such tenant or tenants, for such term or terms ending before, on or after the Fixed Expiration Date, at such rent or rentals and upon such other conditions, which may
include concessions and free rent periods, as Landlord, in Landlord’s sole discretion, may determine; provided, however, that Landlord shall have no obligation to relet the Premises or any part thereof and shall in no event be liable for
refusal or failure to relet the Premises or any part thereof, or, in the event of any such reletting, for refusal or failure to collect any rent due upon any such reletting, and no such refusal or failure shall operate to relieve Tenant of any
liability under this Lease or otherwise affect any such liability, and Landlord, at Landlord’s option, may make such Alterations, in and to the Premises as Landlord, in Landlord’s sole discretion, shall consider advisable or necessary in
connection with any such reletting or proposed reletting, without relieving Tenant of any liability under this Lease or otherwise affecting any such liability. 

  
 51 

 (B) Tenant hereby waives the service of any notice of intention to re-enter or to institute legal
proceedings to that end that may otherwise be required to be given under any present or future law. Tenant, on its own behalf and on behalf of all persons claiming through or under Tenant, including all creditors, does further hereby waive any and
all rights that Tenant and all such persons might otherwise have under any present or future law to redeem the Premises, or to re-enter or repossess the Premises, or to restore the operation of this Lease, after (a) Tenant shall have been
dispossessed by a judgment or by warrant of any court or judge, or (b) any re-entry by Landlord, or (c) any expiration or termination of this Lease and the Term, whether such dispossess, re-entry, expiration or termination is by operation
of law or pursuant to the provisions of this Lease. The words “re-entry”, “re-enter” and “re-entered” as used in this Lease shall not be deemed to be restricted to their technical legal meanings. In the event of a
breach or threatened breach by Tenant, or any persons claiming through or under Tenant, of any term, covenant or condition of this Lease, Landlord shall have the right to enjoin such breach and the right to invoke any other remedy allowed by law or
in equity as if re-entry, summary proceedings and other special remedies were not provided in this Lease for such breach. The right to invoke the remedies hereinbefore set forth are cumulative and shall not preclude Landlord from invoking any other
remedy allowed at law or in equity. 
 Section 19.2 

(A) If this Lease and the Term shall expire and come to an end as provided in Article 18, or by or under any summary proceeding or any
other action or proceeding, or if Landlord shall re-enter the Premises as provided in Section 19.1, or by or under any summary proceeding or any other action or proceeding, then, in any of said events: 

(1) Tenant shall pay to Landlord all Fixed Rent, Escalation Rent, other Additional Rent and other items of Rental payable under this Lease by
Tenant to Landlord to the date upon which this Lease and the Term shall have expired and come to an end or to the date of re-entry upon the Premises by Landlord, as the case may be; 

(2) Tenant also shall be liable for and shall pay to Landlord, as damages, any deficiency (“Deficiency”) between the Rental
for the period which otherwise would have constituted the unexpired portion of the Term and the net amount, if any, of rents collected under any reletting effected pursuant to the provisions of Section 19.1(A)(2) for any part of such
period (after first deducting from the rents collected under any such reletting all of Landlord’s expenses in connection with the termination of this Lease, Landlord’s reentry upon the Premises and such reletting including, but not limited
to, all repossession costs, brokerage commissions, attorneys’ fees and disbursements, alteration costs and other expenses of preparing the Premises for such reletting); any such Deficiency shall be paid in monthly installments by Tenant on the
days specified in this Lease for payment of installments of Fixed Rent; Landlord shall be entitled to recover from Tenant each monthly Deficiency as the same shall arise, and no suit to collect the amount of the Deficiency for any month shall
prejudice Landlord’s right to collect the Deficiency for any subsequent month by a similar proceeding; and 
 (3) whether or not
Landlord shall have collected any monthly Deficiency as aforesaid, Landlord shall be entitled to recover from Tenant, and Tenant shall pay to Landlord, on demand, in lieu of any further Deficiency as and for liquidated and agreed final damages, a
sum equal to the amount by which the unpaid Rental for the period which otherwise 

  
 52 

 
would have constituted the unexpired portion of the Term exceeds the then fair and reasonable rental value of the Premises for the same period, both discounted to present worth at the Base Rate;
if, before presentation of proof of such liquidated damages to any court, commission or tribunal, the Premises, or any part thereof, are relet by Landlord for the period which otherwise would have constituted the unexpired portion of the Term, or
any part thereof, the amount of rent reserved upon such reletting shall be deemed, prima facie, to be evidence of the fair and reasonable rental value for the part or the whole of the Premises so relet during the term of the reletting. 

(B) If the Premises, or any part thereof, shall be relet together with other space in the Building, the rents collected or reserved under any
such reletting and the expenses of any such reletting shall be equitably apportioned for the purposes of this Section 19.2. Tenant shall in no event be entitled to any rents collected or payable under any reletting, whether or not such
rents exceed the Fixed Rent reserved in this Lease. Solely for the purposes of this Article 19, the term “Escalation Rent” as used in Section 19.2(A) shall mean the Escalation Rent in effect immediately prior to
the Expiration Date, or the date of re-entry upon the Premises by Landlord, as the case may be, adjusted to reflect any increase pursuant to the provisions of Article 3 hereof for the Operating Year immediately preceding such event. Nothing
contained in Article 18 or this Article 19 shall be deemed to limit or preclude the recovery by Landlord from Tenant of the maximum amount allowed to be obtained as damages by any statute or rule of law, or of any sums or damages to
which Landlord may be entitled in addition to the damages set forth in this Section 19.2. 
 ARTICLE 20 

FEES AND EXPENSES 

Section 20.1 If (i) an Event of Default shall occur under this Lease, or (ii) Tenant fails to comply with its obligations under
this Lease and Landlord in its good faith determination believes that there is, as a direct result, a material and imminent threat to the preservation of property or the safety of any tenant, occupant or other person, Landlord may (1) perform
the same for the account of Tenant and shall notify Tenant after such performance, or (2) make any expenditure or incur any obligation for the payment of money in connection with any obligation owed to Landlord, including, but not limited to,
reasonable attorneys’ fees and disbursements in instituting, prosecuting or defending any action or proceeding, and in either case the cost thereof, with interest thereon at the Applicable Rate, shall be deemed to be Additional Rent hereunder
and shall be paid by Tenant to Landlord within thirty (30) days after rendition of any bill or statement to Tenant therefor accompanied by reasonable evidence thereof. In addition, Tenant shall pay Landlord any reasonable attorneys’ fees
and disbursements incurred by Landlord in connection with any proceeding in which the value for the use and occupancy of the Premises by Tenant is being determined (whether or not any such proceeding results from a default by Tenant under this
Lease). 
 Section 20.2 If Tenant shall fail to pay any installment of Fixed Rent, Additional Rent or any other item of Rental for a
period longer than five (5) days after the same shall have become due, Tenant shall pay to Landlord, in addition to such installment of Fixed Rent, Additional Rent or other item of Rental, as the case may be, as a late charge and as Additional
Rent, a sum equal to three (3%) percent of the amount unpaid (provided that such three (3%)

  
 53 

 
percent late charge shall not be payable the first time in any twelve (12) consecutive month period that Tenant shall fail to pay an item of Rental for a period longer than five
(5) days after the same shall have become due if such sum shall have been paid within the same calendar month in which the item of Rental is due). If Tenant shall fail to pay any installment of Fixed Rent, Additional Rent or any other item of
Rental for a period longer than 10 days after the same shall have become due, Tenant shall pay to Landlord, in addition to such installment of Fixed Rent, Additional Rent or other item of Rental, as the case may be, and in addition to the late
charge payable by Tenant pursuant to the preceding sentence, as a late charge and as Additional Rent, a sum equal to interest at the Applicable Rate on the amount unpaid. All late charges payable by Tenant hereunder shall be computed from the date
such payment was due (without regard to any grace period set forth in this Section 20.2), to and including the date of payment. 

ARTICLE 21 
 NO REPRESENTATIONS
BY LANDLORD 
 Section 21.1 Landlord and Landlord’s agents have made no representations, warranties or promises with respect
to the Building, the Real Property or the Premises except as herein expressly set forth, and no rights, easements or licenses are acquired by Tenant by implication or otherwise except as expressly set forth herein. Tenant shall accept possession of
the Premises in its “as is” but broom-clean condition on the Commencement Date, and vacant and free of occupants, with Landlord’s Work Substantially Completed. Subject to the performance of Landlord’s Work, Landlord shall have no
obligation to perform any work or make any installations in order to prepare the Premises for Tenant’s occupancy. The taking of occupancy of the whole or any part of the Premises by Tenant shall be conclusive evidence, as against Tenant, that
Tenant accepts possession of the same and that the Premises and the Building were in good and satisfactory condition at the time such occupancy was so taken and that the Premises were substantially as shown on Schedule A, but subject to the
performance by Landlord of the items on Tenant’s Punchlist, and except that if Tenant notifies Landlord in writing of any latent defects in Landlord’s Work within four (4) months after Tenant occupies the Premises for the conduct of
its business, Landlord shall remedy such latent defects (unless such defect was caused by Tenant or Persons Within Tenant’s Control during the performance of any Alterations). The foregoing is not intended to relieve Landlord from its ongoing
repair, maintenance and compliance with Laws obligations under this Lease. All references in this Lease to the consent or approval of Landlord shall be deemed to mean the written consent or approval executed by Landlord and no other consent or
approval of Landlord shall be effective for any purpose whatsoever. Promptly following the conclusion of the four (4) month period after Tenant occupies the Premises for the conduct of its business, Landlord shall assign to Tenant the benefit
of any contractors’ or manufacturers’ warranties applicable to Landlord’s Work. 
 ARTICLE 22 

END OF TERM 

Section 22.1 Upon the expiration or other termination of this Lease, Tenant shall quit and surrender to Landlord the Premises, vacant,
broom clean, in good order and condition, ordinary wear and tear and any damage from casualty or condemnation which Tenant shall not have been obligated to restore hereunder excepted, and Tenant shall remove those of Tenant’s

  
 54 

 
Alterations to the extent required pursuant to Article 6 or any other provision of this Lease. Tenant shall also remove all of Tenant’s Property and all other personal property and
personal effects of all persons claiming through or under Tenant, and shall pay the cost of repairing all damage to the Premises and the Real Property occasioned by such removal. Any Tenant’s Property or other personal property that remains in
the Premises after the termination of this Lease shall be deemed to have been abandoned and either may be retained by Landlord as its property or may be disposed of in such manner as Landlord may see fit. If such Tenant’s Property or other
personal property or any part thereof is sold, Landlord may receive and retain the proceeds of such sale as the property of Landlord. Any expense incurred by Landlord in removing or disposing of such Tenant’s Property or other personal property
or Alterations required to be removed as provided in Article 6, as well as the cost of repairing all damage to the Building or the Premises caused by such removal, shall be reimbursed to Landlord by Tenant, as Additional Rent, on demand. 

Section 22.2 If the Expiration Date falls on a day which is not a Business Day, then Tenant’s obligations under
Section 22.1 shall be performed on or prior to the immediately preceding Business Day. 
 Section 22.3 Tenant expressly
waives, for itself and for any person claiming through or under Tenant, any rights that Tenant or any such person may have under the provisions of Section 2201 of the New York Civil Practice Law and Rules and of any similar or successor law of
like import then in force in connection with any holdover proceedings that Landlord may institute to enforce the provisions of this Article. 

Section 22.4 If the Premises are not surrendered within ninety (90) days after the Expiration Date, Tenant hereby indemnifies
Landlord against liability or expense (including any consequential damages but excluding punitive damages) resulting from delay by Tenant in so surrendering the Premises, including any claims made by any succeeding tenant or prospective tenant
founded upon such delay and agrees to be liable to Landlord for (i) any payment or rent concession which Landlord may be required to make to any tenant obtained by Landlord for all or any part of the Premises in order to induce such tenant not
to terminate its lease by reason of the holding-over by Tenant and (ii) the loss of the benefit of the bargain if any such tenant shall terminate its lease by reason of the holding-over by Tenant. Landlord’s rights under this
Section 22.4 are in addition to the holdover rental payable by Tenant under Section 39.7. 
 Section 22.5
Tenant’s obligations under this Article shall survive the expiration or termination of this Lease. 
 ARTICLE 23 

POSSESSION 

Section 23.1 Except as otherwise set forth in Section 23.2, If Landlord shall be unable to deliver possession of the Premises
or any additional space to be included within the Premises on the specific date (if any) designated in this Lease for any reason whatsoever, Landlord shall not be subject to any liability therefor and the validity of this Lease shall not be impaired
thereby, but the Commencement Date shall be postponed until five (5) Business Days following notice from Landlord that the Premises or such additional space, as the case may be, are 

  
 55 

 
available for occupancy by Tenant. In such event, the Rent Commencement Date and the Fixed Expiration Date shall be delayed by an equal number of days. Tenant expressly waives any right to
rescind this Lease under Section 223-a of the New York Real Property Law or under any present or future statute of similar import then in force and further expressly waives the right to recover any damages that may result from Landlord’s
failure to deliver possession of the Premises or such additional space on the specific date (if any) designated for the commencement of the Term. Tenant agrees that the provisions of this Article 23 are intended to constitute “an express
provision to the contrary” within the meaning of said Section 223-a. 
 Section 23.2 

(i) Notwithstanding the foregoing or anything contained herein to the contrary, provided that this Lease shall be fully executed and delivered
on or prior to 5:00 p.m. on April 30, 2010 (with time being of the essence) and the Plans (as defined in Exhibit C) shall have been approved by Landlord and Tenant on or prior to 5:00 p.m. on April 16, 2010 (with time being of
the essence), Landlord shall endeavor to cause Substantial Completion of Landlord’s Work to occur on or prior to September 15, 2010 (such date, subject to adjustment as set forth in this Section 23.2(i), the “Target
Date”). Provided that no Event of Default shall have occurred and be continuing, if Landlord shall not have achieved Substantial Completion of Landlord’s Work on or prior to the Target Date (as such date shall be extended, on a day for
day basis, by Unavoidable Delays and by delays caused by Tenant or Persons Within Tenant’s Control), Tenant shall be entitled, as Tenant’s sole and exclusive remedy by reason of such delay (other than Tenant’s right to terminate this
Lease as set forth in Section 23.2(ii)), to an additional credit against Fixed Rent commencing on the Rent Commencement Date in the amount of $5,812.81 for each day after the Target Date that the Commencement Date fails to occur. 

(ii) Notwithstanding the foregoing or anything contained herein to the contrary, in the event that Landlord fails to deliver possession of the
Premises to Tenant by November 1, 2010 (such date, subject to adjustment as set forth in this Section 23.2(ii), the “Outside Date”), Tenant shall have the option to terminate this Lease by notice to Landlord given,
if at all, within thirty (30) days after the Outside Date (with time being of the essence), and, in such event, this Lease shall terminate effective as of the thirtieth (30th) day after the date such notice by Tenant is given as if such
termination date were the Expiration Date; provided, however, that if the Commencement Date shall have occurred prior to such thirtieth (30th) day after such notice is given (or if Tenant shall fail to give such notice within the
thirty (30) day period after the occurrence of the Outside Date), Tenant’s exercise of such right to terminate this Lease shall be null and void and of no force or effect. For the purposes of this Section 23.2(ii), the Outside
Date shall be extended, on a day for day basis, by Unavoidable Delays and by delays caused by Tenant or Persons Within Tenant’s Control. Upon termination of this Lease as set forth in this Section 23.2(ii), Landlord shall
immediately return to Tenant the first installment of Fixed Rent and the Security Deposit. Tenant hereby acknowledges and agrees that such rescission right shall be Tenant’s sole and exclusive remedy if the Commencement Date shall not have
occurred on or before the Outside Date, and that Landlord shall have no other liability to Tenant for failure of the Commencement Date to occur. 

(iii) In addition to, and without limiting the foregoing, in the event that the Commencement Date is delayed by Tenant or Persons Within
Tenant’s Control, then Tenant agrees that, the term of this Lease and Tenant’s obligations shall commence on the date that this Lease would have commenced had the Commencement Date not been so delayed by Tenant or Persons Within
Tenant’s Control. 

  
 56 

 ARTICLE 24 

NO WAIVER 

Section 24.1 No act or thing done by Landlord or Landlord’s agents during the Term shall be deemed an acceptance of a surrender of
the Premises, and no agreement to accept such surrender shall be valid unless in writing signed by Landlord. No employee of Landlord or of Landlord’s agents shall have any power to accept the keys to the Premises prior to the termination of
this Lease. The delivery of keys to any employee of Landlord or of Landlord’s agents shall not operate as a termination of this Lease or a surrender of the Premises. If Tenant shall at any time desire to have Landlord sublet the Premises for
Tenant’s account, Landlord or Landlord’s agents are authorized to receive the keys for such purpose without releasing Tenant from any of the obligations under this Lease, and Tenant hereby relieves Landlord of any liability for loss of or
damage to any of Tenant’s effects in connection with such subletting. 
 Section 24.2 The failure of either party to seek redress
for violation of, or to insist upon the strict performance of, any covenant or condition of this Lease, or, in the case of Landlord, any of the Rules and Regulations, shall not prevent a subsequent act, which would have originally constituted a
violation, from having all of the force and effect of an original violation. The receipt by Landlord or payment by Tenant of Fixed Rent, Additional Rent or any other item of Rental with knowledge of the breach of any covenant of this Lease shall not
be deemed a waiver of such breach. The failure of Landlord to enforce any of the Rules and Regulations against Tenant or any other tenant in the Building shall not be deemed a waiver of any such Rules and Regulations. Except as expressly provided to
the contrary in this Lease, no provision of this Lease shall be deemed to have been waived by Landlord or Tenant, unless such waiver shall be in writing and shall be signed by the waiving party. No payment by Tenant or receipt by Landlord of a
lesser amount than the Rental then due and payable shall be deemed to be other than on account of the earliest item(s) of Rental, or as Landlord may elect to apply the same, nor shall any endorsement or statement on any check or any letter
accompanying any check or payment be deemed an accord and satisfaction, and Landlord may accept such check or payment without prejudice to Landlord’s right to recover the balance due of the Rental or pursue any other remedy in this Lease
provided. This Lease contains the entire agreement between the parties and all prior negotiations and agreements are merged herein. Any executory agreement hereafter made shall be ineffective to change, discharge or effect an abandonment of this
Lease in whole or in part unless such executory agreement is in writing and signed by the party against whom enforcement of the change, discharge or abandonment is sought. 

ARTICLE 25 
 WAIVER OF TRIAL BY
JURY 
 Section 25.1 Landlord and Tenant shall and they hereby do waive trial by jury in any action, proceeding or counterclaim
brought by either of them against the other on any matters whatsoever arising out of or in any way connected with this Lease, the relationship of Landlord and Tenant, Tenant’s use or occupancy of the Premises, whether during or after the Term,
or for 

  
 57 

 
the enforcement of any remedy under any statute, emergency or otherwise. If Landlord shall commence any summary proceeding against Tenant, Tenant will not interpose any counterclaim of whatever
nature or description in any such proceeding (unless failure to impose such counterclaim would preclude Tenant from asserting in a separate action the claim which is the subject of such counterclaim), and will not seek to consolidate such proceeding
with any other action which may have been or will be brought in any other court by Tenant or Landlord. 
 ARTICLE 26 

INABILITY TO PERFORM 

Section 26.1 Except as expressly provided to the contrary in this Lease, this Lease and the obligation of Tenant to pay Rental hereunder
and to perform all of the other covenants and agreements hereunder on the part of Tenant to be performed shall in no way be affected, impaired or excused because Landlord is unable to fulfill any of Landlord’s obligations under this Lease,
expressly or implicitly to be performed by Landlord, or because Landlord is unable to make or is delayed in making any repairs, additions, alterations, improvements or decorations, or is unable to supply or is delayed in supplying any services,
equipment or fixtures, if Landlord is prevented from or delayed in so doing by reason of acts of God, casualty, strikes or labor troubles, accident, acts of war, terrorism, bioterrorism (i.e., the release or threatened release of an airborne agent
that may adversely affect the Building or its occupants), governmental preemption in connection with an emergency, Laws, conditions of supply and demand which have been or are affected by war, terrorism, bioterrorism or other emergency, or any other
cause whatsoever, whether similar or dissimilar to the foregoing, beyond Landlord’s reasonable control (“Unavoidable Delays”) (it being understood that a lack of funds shall not constitute an Unavoidable Delay). 

Section 26.2 Tenant shall not be liable for any failure or delay in performing its obligations under this Lease, except for the payment
of any Rental, if Tenant is prevented from or delayed in so doing by reason of acts of God, casualty, strikes or labor troubles, accident, acts of war, terrorism, bioterrorism (as described above), governmental preemption in connection with an
emergency, Laws, conditions of supply and demand which have been or are affected by war, terrorism, bioterrorism or other emergency or any other cause whatsoever, whether similar or dissimilar to the foregoing, beyond Tenant’s reasonable
control. The inability of Tenant to pay for goods or services or to meet its debts shall not excuse Tenant from performing its obligations under this Lease. 

  
 58 

 ARTICLE 27 

BILLS AND NOTICES 

Section 27.1 
 (A) Except
as otherwise expressly provided in this Lease, any bills, statements, consents, notices, demands, requests or other communications given or required to be given under this Lease (“Notice(s)”) shall be in writing and shall be deemed
sufficiently given or rendered only if delivered by hand (against a signed receipt), by a recognized overnight courier service (with a signed receipt) or if deposited in a securely fastened, postage prepaid envelope in a depository that is regularly
maintained by the U.S. Postal Service, sent by registered or certified mail (return receipt requested) and in any case addressed: 
 if to
Tenant (a) at 400 Technology Square, Cambridge, MA 02139, Attention: Vice President – Corporate Services, or at any place where Tenant or any agent or employee of Tenant may be found if given subsequent to Tenant’s vacating,
deserting, abandoning or surrendering such address, with simultaneous copies to each of: 
  

	 	(i)	Forrester Research, Inc. 

 400 Technology Square 

Cambridge, MA 02139 
 Attention:
Chief Financial Officer 
 and 
  

	 	(ii)	Forrester Research, Inc. 

 400 Technology Square 

Cambridge, MA 02139 
 Attention:
Chief Legal Officer 
 and 
  

	 	(iii)	Dionne & Gass LLP 

 131 Dartmouth Street 

Suite 501 
 Boston, MA 02116

 Attention: Joanne A. Robbins, Esq. 

if to Landlord, at Landlord’s address set forth in this Lease, Attn: General Counsel, with simultaneous copies to each of: 

 

	 	(i)	RFR Realty LLC 

 390 Park Avenue 

New York, New York 10022 

Attention: President 
  

	 	(ii)	Loeb & Loeb LLP 

 345 Park Avenue 

New York, New York 10154 

Attention: Raymond A. Sanseverino, Esq. 

and 
  

	 	(iii)	any Mortgagee or Lessor who may have requested the same, by Notice given in accordance with the provisions of this Article 27, at the address designated by such Mortgagee or Lessor. 

  
 59 

 Landlord or Tenant may designate new address(es) by notice given to the other in accordance with
the provisions of this Article 27. 
 (B) Notices shall be deemed to have been rendered or given (i) on the Business Day
delivered, if delivered by hand or by recognized overnight courier service, prior to 5:00 p.m. of such Business Day, or if delivered on a day other than a Business Day or after 5:00 p.m. on any day, then on the next Business Day following such
delivery, or (ii) three (3) Business Days after the date mailed, if mailed as provided in Section 27.1(A). Notice given by counsel for either party on behalf of such party or by the Manager on behalf of Landlord shall be deemed
valid notices if addressed and sent in accordance with the provisions of this Article. 
 Section 27.2 Notwithstanding the provisions
of Section 27.1, Notices requesting services for Overtime Periods pursuant to Article 28 may be given by delivery to the Building superintendent or any other person in the Building designated by Landlord to receive such Notices,
and bills may be sent by first class mail or delivered to the Premises without receipt. 
 ARTICLE 28 

SERVICES AND EQUIPMENT 

Section 28.1 Landlord shall, at Landlord’s expense: 

(A) Provide passenger elevator service to the Premises on Business Days during Operating Hours and, subject to Section 28.3, have
at least one passenger elevator on call at all other times. Tenant agrees that Landlord may, at its election, install elevators with or without operators and may change the same from time to time. 

(B) Tenant acknowledges that the Building does not have a dedicated freight elevator. Provided that no other tenants are physically occupying
any space on floors 2 through 9 of the Building, Landlord shall dedicate one passenger elevator for Tenant’s non-exclusive use, at no charge, during Operating Hours, for the first thirty (30) days after the Commencement Date. If another
tenant is in physical occupancy of any space on floors 2-9 of the Building during such thirty (30) day period, then any Major Delivery of construction materials shall be scheduled on Business Days after Operating Hours, at the charges set forth
in Section 28.2. After such thirty (30) day period, Landlord shall provide one passenger elevator for freight purposes on a reservation, “first come, first served” basis during Overtime Periods, as further described in
Section 28.2. “Major Delivery” shall mean any delivery of materials, furniture or equipment that either (i) exceeds the weight capacity of the elevators in the Building or (ii) does not fit within the openings
of the elevators in the Building. 
 (C) Landlord has installed in the Premises a new United Air Cool, air-cool DX air conditioning unit,
with electric heating coil, that can accommodate either a variable or constant volume control (the “DX Unit”). The DX Unit shall have a 30 ton capacity and shall be connected to Tenant’s electrical submeters to measure its
consumption of electricity. Tenant shall have control of the operation of the DX Unit 24 hours per day, seven days per week. Landlord shall furnish heat or ventilation (as needed), to the Premises from October 15 through April 30 through a
centrally located boiler and perimeter fin tube radiator, containing thermostatic control valves in the Premises controlled by Tenant, during Operating Hours. 

  
 60 

 
Tenant shall draw and close the draperies or blinds for the windows of the Premises whenever the HVAC System is in operation and the position of the sun so requires and shall, at all times,
reasonably cooperate with Landlord and abide by all of the Rules and Regulations which Landlord may prescribe for the proper functioning of the HVAC System. Tenant expressly acknowledges and agrees that Tenant shall not permit any of the windows in
the Premises to be opened as the same shall interfere with the proper operation of the HVAC System (provided, however, that the opening of any window(s) in the Premises shall not entitle Landlord to terminate this Lease or to take
possession of the Premises, provided further, however, that Tenant shall be liable to Landlord for any and all damages (including, without limitation, water damage and freezing damage) caused to the Building and/or the Building
Systems due to the opening of such window(s) in the Premises). Tenant hereby expressly waives any claims against Landlord arising out of the cessation of operation of the HVAC System, or the suitability of the Premises when the same is not in
operation, whether due to normal scheduling or the reasons set forth in Section 28.3. Landlord will not be responsible for the failure of the HVAC System if such failure results from the occupancy of the Premises by more than an average
of one person for each 100 square feet of usable area or if Tenant uses in excess of six (6) watts connected load of electricity per rentable square foot (or if Tenant shall fail to keep the windows in the Premises closed or to draw and close
the draperies or blinds as required hereunder). If Tenant occupies the Premises at an occupancy rate of greater than that for which the HVAC System was designed (1 person per 100 square feet of usable area), or uses in excess of six (6) watts
connected load of electricity per rentable square foot or if Tenant’s partitions are arranged in such a way as to interfere with the normal operation of the HVAC System, Landlord may elect to make changes to the HVAC System or the ducts through
which it operates required by reason thereof, and the cost thereof shall be reimbursed by Tenant to Landlord as Additional Rent within thirty (30) days after presentation of a bill therefor. Landlord, throughout the Term, shall have free access
to all mechanical installations of Landlord, including but not limited to air-cooling, fan, ventilating and machine rooms and electrical closets, and Tenant shall not construct or place partitions, furniture or other obstructions that may interfere
with Landlord’s free access thereto or the proper functioning of Building Systems, or interfere with the moving of Landlord’s equipment to and from the enclosures containing said installations. Neither Tenant nor its agents, employees or
contractors shall at any time enter the said enclosures or tamper with, adjust, touch or otherwise in any manner affect said mechanical installations. Landlord’s obligations under this Section 28.1 and under Section 28.2
are subject to applicable Laws that may limit the hours or the extent to which Landlord is permitted to supply HVAC. 
 (D) Furnish cold
water for ordinary drinking, cleaning, pantry and lavatory purposes. If Tenant requires, uses or consumes water for any other purposes, Tenant agrees that Tenant shall install a meter or meters or other means to measure Tenant’s water
consumption, and Tenant further agrees to pay for the cost of the meter or meters and the installation thereof, and to pay for the maintenance of said meter equipment and/or to pay Landlord’s cost of other means of measuring such water
consumption by Tenant. In such event, Tenant shall reimburse Landlord for the cost of all water consumed as measured by said meter or meters or as otherwise measured, including sewer rents, as Additional Rent within thirty (30) days after bills
are rendered. If Tenant wishes to use hot water for its pantries or lavatories, Tenant, at its sole cost and expense and in accordance with Article 6, shall install a system to generate such hot water. 

(E) Provided Tenant shall keep the Premises in order, Landlord, at Landlord’s expense, shall cause the Premises, and excluding any
portions thereof used as security areas or 

  
 61 

 
used for the storage, preparation, service or consumption of food or beverages, to be cleaned on Business Days in accordance with the cleaning specifications annexed to this Lease as
Schedule D. If, however, any additional cleaning of the Premises is to be done by Tenant, it shall be done at Tenant’s sole expense, in a manner reasonably satisfactory to Landlord and no one other than persons approved by Landlord
shall be permitted to enter the Premises or the Building for such purpose. Tenant shall pay to Landlord the cost of removal of any of Tenant’s refuse and rubbish from the Premises and the Building (i) to the extent that the same, in any
one day, exceeds the average daily amount of refuse and rubbish usually attendant upon the use of such Premises as offices, as described and included in Landlord’s cleaning contract for the Building or as reasonably recommended by
Landlord’s cleaning contractor, and (ii) related to or deriving from the preparation or consumption of food or drink. Bills for the same shall be rendered by Landlord to Tenant at such time as Landlord may elect and shall be due and
payable as Additional Rent within thirty (30) days after the time rendered. Tenant shall cause all portions of the Premises used for the storage, preparation, service or consumption of food or beverages to be cleaned daily in a manner
reasonably satisfactory to Landlord, and to be treated against infestation by vermin, rodents or roaches, whenever there is evidence of any infestation. Tenant shall not permit any person to enter the Premises or the Building for the purpose of
providing such extermination services, unless such persons have been approved by Landlord, which approval shall not be unreasonably withheld, conditioned or delayed. If so requested by Landlord, Tenant, at Tenant’s expense, shall store any
refuse generated by the consumption of food or beverages on the Premises in a cold box or similar facility. 
 (F) Subject to the Rules and
Regulations, Tenant (and its employees, permitted subtenants and occupants, and invitees) shall have access to the Premises 24 hours per day seven (7) days per week. 

(G) Landlord shall maintain and provide security systems, procedures and personnel for the Building on a 24-hour per day basis, including
(i) a manned concierge desk in the lobby of the Building which shall provide for controlled access into the Building and cameras at lobby doors and (ii) a card key access system through the elevators and to tenant spaces during
non-Operating Hours. 
 (H) If the “sprinkler system” installed in the Building or any of its appurtenances are damaged or injured
or not in proper working order by reason of any act or omission of Tenant or of Persons Within Tenant’s Control, Tenant shall forthwith restore the same to good working condition at Tenant’s expense; and if the New York Board of Fire
Underwriters or the New York Insurance Rating Organization or any Government Authority requires or recommends that any changes, modifications, alterations or additional sprinkler heads or other equipment be made or supplied by reason of
Tenant’s business, or the location of the partitions, trade fixtures, or other contents of the Premises, Landlord shall, at Tenant’s expense, promptly make and supply such changes, modifications, alterations, additional sprinkler heads or
other equipment (pursuant to submission of necessary engineering plans and specifications for Landlord’s approval). 

Section 28.2 The Fixed Rent does not reflect or include any charge to Tenant for the furnishing of any necessary elevator facilities for
freight purposes or heat to the Premises during periods (“Overtime Periods”) other than the hours and days set forth above. Accordingly, if Landlord furnishes any such elevator facilities for freight purposes or heat to the Premises
at the 

  
 62 

 
request of Tenant during Overtime Periods, Tenant shall pay Landlord Additional Rent for such services at the standard rates then fixed by Landlord for the Building. Landlord shall not be
required to furnish any such services during any Overtime Periods unless Landlord has received advance notice from Tenant requesting such services prior to 2:00 p.m. of the day upon which such services are requested or by 2:00 p.m. of the last
preceding Business Day if such Overtime Periods are to occur on a day other than a Business Day. If Tenant fails to give Landlord such advance notice, then failure by Landlord to furnish or distribute any such services during such Overtime Periods
shall not constitute an actual or constructive eviction, in whole or in part, or entitle Tenant to any abatement or diminution of Rental, or relieve Tenant from any of its obligations under this Lease, or impose any liability upon Landlord or its
agents by reason of inconvenience or annoyance to Tenant, or injury to or interruption of Tenant’s business or otherwise. 

Section 28.3(A) Landlord reserves the right to stop the furnishing of the Building services and to stop service of the Building Systems,
when necessary, by reason of accident, or emergency, or for Alterations in the judgment of Landlord advisable or necessary to be made, until said Alterations shall have been completed; and Landlord shall have no responsibility or liability for
failure to supply air-conditioning, ventilation, heat, elevator, plumbing, electric, or other services during said period or when prevented from so doing by strikes, lockouts, labor troubles, difficulty of obtaining materials, accidents or by any
cause beyond Landlord’s reasonable control, or by Laws or failure of electricity, water, steam, coal, oil or other suitable fuel or power supply, or inability by exercise of reasonable diligence to obtain electricity, water, steam, coal, oil or
other suitable fuel or power. Except as otherwise expressly provided in this Lease, no diminution or abatement of rent or other compensation shall or will be claimed by Tenant as a result therefrom, nor shall this Lease or any of the obligations of
Tenant be affected or reduced by reason of such interruption, curtailment or suspension, nor shall the same constitute an actual or constructive eviction. Without limiting events that may constitute “any cause beyond Landlord’s reasonable
control,” the following are items which Landlord and Tenant agree are beyond Landlord’s reasonable control: 
 (1) Lack of access
to the Building or the Premises (which shall include, but not be limited to, the lack of access to the Building or the Premises when it or they are structurally sound but inaccessible due to the actions of a Government Authority, the evacuation of
the surrounding area or damage to nearby structures or public areas); 
 (2) any cause outside the Building; 

(3) Reduced air quality or other contaminants within the Building that would adversely affect the Building or its occupants (including, but
not limited to, the presence of biological or other airborne agents within the Building or the Premises); 
 (4) Disruption of mail and
deliveries to the Building or the Premises resulting from a casualty; 
 (5) Disruption of telephone and telecommunications services to the
Building or the Premises resulting from a casualty; or 
 (6) Blockages of any windows, doors, or walkways to the Building or the Premises
resulting from a casualty. 

  
 63 

 (B) Notwithstanding anything to the contrary contained herein, if, by reason of Landlord’s
failure to (i) provide (I) the electricity required to be provided to the Premises by Landlord under Article 4 hereof, or (II) water service to the entire Building or (III) access to the Premises, and in any such case,
such failure is due to the negligence or wrongful act or wrongful omission of Landlord or its agents, employees or contractors, or (ii) make repairs required to be made by Landlord pursuant to this Lease (or if due to the performance of such
repairs by Landlord), or (iii) provide the services required to be provided by Landlord under Sections 28.1(A), (B) and (C) (such required electrical service, water service to the Building, and access to the Premises, or
required repairs or service obligations set forth in this Section 28.3(B) being referred to individually and/or collectively as “Critical Services”), and as a result thereof a material portion of the Premises is rendered
untenantable for the conduct of Tenant’s business and Tenant ceases to use such portion of the Premises for the conduct of its business, and Landlord’s failure to provide such Critical Services continues unremedied for more than five
(5) consecutive Business Days after Tenant gives written notice to Landlord of such failure and the fact that a material portion of the Premises has been rendered untenantable for the conduct of Tenant’s business by reason of such Landlord
failure and that Tenant shall have ceased using such portion of the Premises for the conduct of its business, then the Fixed Rent and the Escalation Rent shall be abated during the time that such portion remains so untenantable and unused by reason
of such Landlord failure to provide such Critical Services after such fifth (5th) consecutive Business Day, apportioned according to the rentable area of the Premises so rendered untenantable and unused. Nothing contained in this
Section 28.3(B) is intended to, or shall be deemed to, make any event described in or contemplated by Articles 13, 14 or 26 or Section 28.3(A) or any event resulting from an act or omission of Tenant or Persons Within
Tenant’s Control, a Landlord failure to provide Critical Services. 
 Section 28.4 Tenant agrees to reasonably cooperate with
Landlord, and to abide by all reasonable requirements which Landlord may prescribe, to ensure the effective and energy-efficient operation of the Building, and for the proper protection and functioning of its Building Systems and the furnishing of
the Building services; provided, however, that such cooperation shall not entail any unreasonable interference with Tenant’s use or occupancy of, or access to, the Premises. Tenant further agrees to reasonably cooperate with Landlord in any
conservation effort pursuant to a program or procedure promulgated or recommended by the public utility serving the Building, or ASHRAE or any Requirements. 

Section 28.5 Landlord shall have no obligation to clean, repair, replace or maintain any “private” plumbing fixtures or
facilities (i.e., plumbing fixtures and facilities other than those that would be the common toilets in a multi-tenant floor) or the rooms in which they are located. 

Section 28.6 Tenant acknowledges that the Building does not contain facilities to furnish condenser or chilled water to the Premises.
Subject to Tenant’s compliance with all of the provisions of Article 6 with respect to Alterations, Landlord approves in concept the installation by Tenant, at its sole cost and expense, of air-cooled supplemental air-conditioning units
to service specialized areas of the Premises. 

  
 64 

 Section 28.7 Landlord shall provide Tenant reasonable and non-exclusive access to use a 2 1⁄2 inch sleeve from the basement to the roof of the Building designated by Landlord which may be reasonably required for Tenant’s installation, removal,
replacement, repair, maintenance and operation therein, at Tenant’s sole cost and expense, of lines, cables, conduits and other installations for telecommunications purposes. All such installations shall be subject to Landlord’s reasonable
review and approval. Landlord shall not unreasonably withhold its consent to Tenant’s proposed telecommunications providers, so long as they execute Landlord’s commercially reasonable standard form of license agreement. 

ARTICLE 29 
 PARTNERSHIP TENANT

 Section 29.1 If Tenant is a partnership, or is comprised of two (2) or more persons, individually or as co-partners of a
partnership (any such partnership and such persons are referred to in this Article 29 as “Partnership Tenant”), or if Tenant’s interest in this Lease shall be assigned to a Partnership Tenant, the following provisions
shall apply to such Partnership Tenant: (a) the liability of each of the parties comprising Partnership Tenant shall be joint and several; (b) each of the parties comprising Partnership Tenant hereby consents in advance to, and agrees to
be bound by (i) any written agreement that may hereafter be executed by Partnership Tenant or any successor entity, changing, extending or discharging this Lease, in whole or in part, or surrendering all or any part of the Premises to Landlord,
and (ii) any Notices that may hereafter be given by Partnership Tenant or by any of the parties comprising Partnership Tenant; (c) any Notices given or rendered to Partnership Tenant or to any of such parties shall be binding upon
Partnership Tenant and all such parties; (d) if Partnership Tenant admits new partners, all of such new partners shall, by their admission to Partnership Tenant, be deemed to have assumed joint and several liability for the performance of all
of the terms, covenants and conditions of this Lease on Tenant’s part to be observed and performed; (e) Partnership Tenant shall give prompt notice to Landlord of the admission of any such new partners, and upon demand of Landlord, shall
cause each such new partner to execute and deliver to Landlord an agreement in form satisfactory to Landlord, wherein each such new partner assumes joint and several liability for the performance of all the terms, covenants and conditions of this
Lease on Tenant’s part to be observed and performed (but neither Landlord’s failure to request any such agreement nor the failure of any such new partner to execute or deliver any such agreement to Landlord shall vitiate the provisions of
clause (d) of this Article 29); and (f) any present or future partner of Partnership Tenant who is no longer a partner of Partnership Tenant at the time of any default under this Lease shall, nevertheless, remain liable for the
obligations of Tenant under this Lease, as if any such partner had been a partner of Partnership Tenant on the date of such default. The provisions of this Article 29 shall be inapplicable to the Tenant named in this Lease and to its
corporate successors under Section 15.3(B). 
 ARTICLE 30 

VAULT SPACE 

Section 30.1 Notwithstanding anything contained in this Lease or indicated on any sketch, blueprint or plan, any vaults, vault space or
other space outside the boundaries of the Real Property are not included in the Premises. Landlord makes no representation as to the 

  
 65 

 
location of the boundaries of the Real Property. All vaults and vault space and all other space outside the boundaries of the Real Property which Tenant may be permitted to use or occupy are to
be used or occupied under a revocable license, and if any such license is revoked, or if the amount of such space is diminished or required by any Government Authority or by any public utility company, such revocation, diminution or requisition
shall not constitute an actual or constructive eviction, in whole or in part, or entitle Tenant to any abatement or diminution of Rental, or relieve Tenant from any of its obligations under this Lease, or impose any liability upon Landlord. Any fee,
tax or charge imposed by any Government Authority for any such vaults, vault space or other space occupied by Tenant shall be paid by Tenant. 

ARTICLE 31 
 SIGNS 

Section 31.1 The location, size, materials, quality, design, color and lettering of any signs desired by Tenant, including in the
elevator lobby of the Premises, shall be subject to the prior approval of Landlord (which Landlord shall not unreasonably withhold, condition or delay) and shall be subject to the terms of this Article 31 and in compliance with the standards
set forth in the Building and Rules and Building Standards for Alterations. At Landlord’s option, Landlord may install any such signs, and Tenant shall pay all reasonable costs associated with such installation, as Additional Rent, within
thirty (30) days after demand therefor, together with customary back-up documentation. 
 ARTICLE 32 

BROKER 
 Section 32.1
Landlord represents and warrants to Tenant that Landlord has not dealt with any broker or Person in connection with this Lease other than the Broker(s). Tenant represents and warrants to Landlord that Tenant has not dealt with any broker or Person
in connection with this Lease other than the Broker(s). The execution and delivery of this Lease shall be conclusive evidence that the parties have relied upon the foregoing representation and warranty. Landlord and Tenant shall indemnify and hold
harmless the other party from and against any and all claims for commission, fee or other compensation by any Person (other than the Broker(s) with respect to Tenant’s indemnity to Landlord) who claims to have dealt with the indemnitor in
connection with this Lease and for any and all costs incurred by the indemnitee in connection with such claims, including, without limitation, reasonable attorneys’ fees and disbursements. Landlord shall pay Broker their commissions pursuant to
separate agreement. This provision shall survive the expiration or earlier termination of this Lease. 
 ARTICLE 33 

INDEMNITY 

Section 33.1 Tenant shall not do or permit any act or thing to be done upon the Premises or the Real Property by any Person Within
Tenant’s Control that may subject any Indemnitee to any liability or responsibility for injury, damage to persons or property or to any liability by reason of the existence or application of, compliance with or violation of any

  
 66 

 
Requirement, but shall exercise such control over the Premises as to protect each Indemnitee fully against any such liability and responsibility. Tenant shall indemnify and save harmless the
Indemnitees from and against (a) all claims of whatever nature against the Indemnitees arising from any act, omission or negligence of Tenant or Persons Within Tenant’s Control, (b) all claims against the Indemnitees arising from any
accident, injury or damage whatsoever caused to any person or to the property of any person and occurring in or about the Premises during the Term or during Tenant’s occupancy of the Premises, unless and to the extent caused by the act,
omission or negligence of Landlord, the Manager or its principals, officers, employees, agents or contractors, (c) all claims against the Indemnitees arising from any accident, injury or damage occurring outside of the Premises but anywhere
within or about the Real Property, where such accident, injury or damage results or is claimed to have resulted from an act, omission or negligence of Tenant or Persons Within Tenant’s Control, and (d) any breach, violation or
non-performance of any covenant, condition or agreement contained in this Lease to be fulfilled, kept, observed and performed by Tenant. This indemnity and hold harmless agreement shall include indemnity from and against any and all liability,
fines, suits, demands, costs and expenses of any kind or nature (including, without limitation, reasonable attorneys’ fees and disbursements) incurred in or in connection with any such claim or proceeding brought thereon, and the defense
thereof, but shall be offset to the extent of any insurance proceeds collected by the Indemnitees under policies covering the Indemnitees. In addition, the foregoing indemnity shall exclude consequential damages, other than as set forth in
Section 22.4. 
 Section 33.2 Except to the extent otherwise expressly limited in this Lease, Landlord shall indemnify and
save Tenant harmless from and against (a) all claims of whatever nature against Tenant and its shareholders, officers, directors, employees, agents and contractors (“Tenant Indemnitees”) arising from any willful misconduct or
negligence of Landlord or Persons Within Landlord’s Control, (b) all claims against Tenant Indemnitees arising from any accident, injury or damage occurring within or about the Real Property to the extent such accident, injury or damage
results or is claimed to have resulted from the willful misconduct or negligence of Landlord or Persons Within Landlord’s Control, and (c) any breach, violation or non-performance of any covenant, condition or agreement contained in this
Lease to be fulfilled, kept, observed and performed by Landlord. This indemnity and hold harmless agreement shall include indemnity from and against any and all liability, fines, suits, demands, costs and expenses of any kind of nature (including,
without limitation, reasonable attorneys’ fees and disbursements) incurred in or in connection with any such claims or proceeding brought thereon, and the defense thereof, but shall be offset to the extent of any insurance proceeds collected by
Tenant Indemnitees under policies covering Tenant Indemnitees. In addition, the foregoing indemnity shall exclude consequential damages. 

Section 33.3 If any claim, action or proceeding is made or brought against (i) any Indemnitee, against which claim, action or
proceeding Tenant is obligated to indemnify such Indemnitee pursuant to the terms of this Lease, or (ii) any Tenant Indemnitee against which claim, action or proceeding Landlord is obligated to indemnify such Tenant Indemnitee pursuant to the
terms of this Lease, then, upon demand by the Indemnitee or Tenant Indemnitee (as the case may be), the applicable indemnitor, at its sole cost and expense, shall resist or defend such claim, action or proceeding in the Indemnitee’s or
Tenant’s Indemnitee’s name if necessary, by such attorneys as the indemnitor may select, subject to the Indemnitee’s or Tenant’s Indemnitee’s reasonable consent. Notwithstanding the foregoing, an Indemnitee or a Tenant
Indemnitee may retain its own attorneys to defend or assist in defending any claim, action or 

  
 67 

 
proceeding involving potential liability of Seven Million Five Hundred Thousand Dollars ($7,500,000) or more, and the indemnitor shall pay the reasonable fees and disbursements of such attorneys.
The provisions of this Article 33 shall survive the expiration or earlier termination of this Lease. 
 ARTICLE 34 

ADJACENT EXCAVATION; SHORING 

Section 34.1 If an excavation shall be made upon land adjacent to the Building, or shall be authorized to be made, Tenant shall, upon
reasonable advance notice, afford to the person causing or authorized to cause such excavation, license to enter upon the Premises for the purpose of doing such work as said person shall deem necessary to preserve the walls of the Building from
injury or damage and to support the same by proper foundations without any claim for eviction or constructive eviction, damages or indemnity against Landlord, or diminution or abatement of Rental, provided that Tenant continues to have access to the
Premises for the conduct of its business therein. 
 ARTICLE 35 

OPTION TO CANCEL 

Section 35.1 Provided that (i) an Event of Default under this Lease shall not then be continuing, (ii) this Lease shall be in
full force and effect at all times mentioned below, and (iii) Tenant shall not have assigned its interest in this Lease in a transaction requiring Landlord’s consent, Tenant shall have the one-time right to cancel this Lease effective as
of the seventh (7th) anniversary of the Rent Commencement Date (the “Cancellation Option Termination Date”), provided that (A) Tenant shall have given Landlord, at least
twelve (12) months prior to the Cancellation Option Termination Date, a notice (the “Cancellation Notice”) of Tenant’s cancellation of this Lease effective as of the Cancellation Option Termination Date, and
(B) Tenant shall have paid Landlord, simultaneously with the giving of the Cancellation Notice, an amount equal to (x) the unamortized costs incurred and paid by Landlord in connection with this Lease for (a) brokerage commissions,
(b) free rent, and (c) the cost of Landlord’s Work and the Tenant Improvement Allowance, all amortized on a straight-line basis over the originally scheduled Term, at an annual interest rate of 8% (the “Cancellation
Payment”). Upon Tenant’s request, Landlord shall promptly deliver to Tenant an itemized list of such costs incurred by Landlord and, where applicable, evidence of such costs. Time is of the essence with respect to the giving of the
Cancellation Notice by Tenant and the making of the Cancellation Payment by Tenant by the date set forth above. Upon the timely giving of the Cancellation Notice and the timely payment of the Cancellation Payment, the Term of this Lease shall expire
on the Cancellation Option Termination Date as if such date were the Fixed Expiration Date and neither party shall have any further rights or obligations under this Lease, except for such rights and obligations which expressly survive the
termination or expiration of the Term of this Lease. 

  
 68 

 ARTICLE 36 

RENT REGULATION 

Section 36.1 If at any time or times during the Term of this Lease, the Rental reserved in this Lease is not fully collectible by reason
of any Law, Tenant shall enter into such agreements and take such other steps (without additional expense to Tenant) as Landlord may request and as may be legally permissible to permit Landlord to collect the maximum rents that may from time to time
during the continuance of such legal rent restriction be legally permissible (and not in excess of the amounts reserved under this Lease). Upon the termination of such legal rent restriction (a) the Rental shall become and thereafter be payable
hereunder in accordance with the amounts reserved in this Lease for the remainder of the Term, and (b) Tenant shall pay to Landlord, if legally permissible, an amount equal to (i) the items of Rental that would have been paid pursuant to
this Lease but for such legal rent restriction less (ii) the rents paid by Tenant to Landlord during the period or periods such legal rent restriction was in effect. This provision shall survive the expiration or earlier termination of this
Lease to the maximum enforceable extent. 
 ARTICLE 37 

COVENANT OF QUIET ENJOYMENT 

Section 37.1 Landlord covenants that, upon Tenant paying the Fixed Rent and Additional Rent and observing and performing all the terms,
agreements, covenants, provisions and conditions of this Lease on Tenant’s part to be observed and performed, Tenant may peaceably and quietly enjoy the Premises, subject nevertheless to the terms and conditions of this Lease, and provided,
however, that no eviction of Tenant by reason of the foreclosure of any Mortgage now or hereafter affecting the Premises or by reason of any termination of any Superior Lease to which this Lease is subject and subordinate, whether such termination
is effected by operation of law, by agreement or otherwise, shall be construed as a breach of this covenant nor shall any action by reason thereof be brought against Landlord, and provided further that this covenant shall bind and be enforceable
against Landlord or any successor to Landlord’s interest, subject to the terms hereof, only so long as Landlord or any successor to Landlord’s interest, is in possession and is collecting rent from Tenant but not thereafter. 

ARTICLE 38 
 ICIP PROGRAM

 Section 38.1 Landlord hereby notifies Tenant that Landlord intends to avail itself of certain exemptions and/or abatements of
Taxes under the Industrial and Commercial Incentive Program (“ICIP”) in connection with the renovation of the Building, including any work to be performed by Landlord in the Premises. Tenant agrees to comply, and to cause its
contractors and subcontractors performing Alterations in the Premises to comply, with all rules and regulations of the ICIP in effect from time to time, including, but not limited to, the filing requirements of the New York City Department of
Finance (“DOF”) and the New York City Department of Small Business Services (“DSBS”) with respect to all Alterations performed by Tenant in the Premises and the Building. In connection therewith, all of
Tenant’s construction 

  
 69 

 
managers, contractors and subcontractors employed in connection with the Alterations shall be contractually required by Tenant to comply with DSBS requirements currently and hereinafter
applicable to construction projects benefiting from the ICIP. Such compliance, as of the date hereof, includes the following: the submission and approval of a Construction Employment Report, attendance at a pre-construction conference with
representatives of DSBS and adherence to the provisions of Article 22 of the ICIP Rules and Regulations, the provisions of the New York City Charter Chapter 13B and the provisions of Executive order No. 50 (1980) and cooperation with
Landlord with respect to Landlord’s application to obtain the ICIP exemption and/or abatements and the implementation of the ICIP through the period that the program shall be in effect. Promptly following knowledge or receipt of notice of any
failure of any contractor or subcontractor to comply with such contractual provisions regarding DSBS compliance, Tenant shall use all commercially reasonable efforts to enforce such contractual DSBS compliance obligations, including, without
limitation, by way of termination of such contracts and/or subcontracts. 
 Section 38.2 Prior to performing the Alterations, obtaining
building permits in connection with the Alterations or executing an agreement with a contractor to perform the Alterations, Tenant shall direct its architect or engineer to prepare a narrative description of the project with a construction budget.
In addition, Tenant shall (i) upon Landlord’s request and upon thirty (30) days notice to Tenant, report annually to Landlord the use of the Premises, number of workers permanently engaged in employment in the Premises, the nature of
each worker’s employment, and to the extent applicable, the New York City residency of each worker, (ii) provide access to the Premises by employees and agents of the Department (as such term is defined in the ICIP rules and regulations)
at all reasonable times, (iii) enforce the contractual obligations of Tenant’s construction managers, contractors, and subcontractors to comply with the DSBS requirements, (iv) timely submit required ICIP documentation which shall
include copies of blueprints, plans, building permits, (v) furnish to Landlord (and cause its contractors and subcontractors to so furnish), simultaneously with the submission to any agency administering the ICIP, copies of all documents
submitted by Tenant or required to be submitted by Tenant in connection with the ICIP (and cause its contractors and subcontractors to do the same) and (vi) submit to Landlord on completion of the Alterations, an architect’s letter of
completion, a summary by trade of the costs incurred in the performance of such Alterations, certified by a reputable, independent certified public accountant. Tenant agrees to cause all such information and reports to be supplied within the time
limits for submitting such information. 
 Section 38.3 The ICIP imposes certain requirements with respect to construction managers,
contractors and subcontractors performing Alterations in the Building. Tenant agrees that it shall use only those contractors that qualify under and satisfy the requirements of the ICIP. 

ARTICLE 39 
 MISCELLANEOUS

 Section 39.1 This Lease is presented for signature by Tenant and it is understood that this Lease shall not constitute an offer
by or be binding upon Landlord or Tenant unless and until Landlord and Tenant shall have executed and delivered a fully executed copy of this Lease to the other. 

  
 70 

 Section 39.2 The obligations of Landlord under this Lease shall not be binding upon Landlord
named herein after the sale, conveyance, assignment or transfer by such Landlord (or upon any subsequent landlord after the sale, conveyance, assignment or transfer by such subsequent landlord) of its interest in the Building or the Real Property,
as the case may be, and in the event of any such sale, conveyance, assignment or transfer, Landlord shall be and hereby is entirely freed and relieved of all covenants and obligations of Landlord under this Lease thereafter arising, and the
transferee shall be deemed to have assumed, subject to the remaining provisions of this Section 39.2, all obligations of the Landlord under this Lease arising after the effective date of the transfer. No trustee, partner, shareholder,
director or officer of Landlord, or of any partner or shareholder of Landlord (collectively, the “Parties”) shall have any direct or personal liability for the performance of Landlord’s obligations under this Lease, and Tenant
shall look solely to Landlord’s interest in the Real Property (and the net proceeds derived therefrom) to enforce Landlord’s obligations hereunder and shall not otherwise seek any damages against Landlord personally or any of the Parties
whatsoever. Tenant shall not look to any other property or assets of Landlord or any property or assets of any of the Parties in seeking either to enforce Landlord’s obligations under this Lease or to satisfy a judgment for Landlord’s
failure to perform such obligations. 
 Section 39.3 Notwithstanding anything contained in this Lease to the contrary, all amounts
payable by Tenant to or on behalf of Landlord under this Lease, whether or not expressly denominated Fixed Rent, Escalation Rent, Additional Rent or Rental, shall constitute rent for the purposes of Section 502(b)(7) of the Bankruptcy
Code. 
 Section 39.4 Intentionally Omitted. 

Section 39.5 Except as otherwise expressly stated in this Lease, any consent or approval required to be obtained from Landlord may be
granted by Landlord in its sole discretion. In any instance in which Landlord agrees not to act unreasonably, Tenant hereby waives any claim for damages against or liability of Landlord that Tenant may have based upon any assertion that Landlord has
unreasonably withheld, unreasonably conditioned or unreasonably delayed any consent or approval requested by Tenant, and Tenant agrees that its sole remedy shall be an action or proceeding to enforce any related provision or for specific
performance, injunction or declaratory judgment. If with respect to any required consent or approval Landlord is required by the express provisions of this Lease not to unreasonably withhold, condition or delay its consent or approval, and if it is
determined in any such proceeding referred to in the preceding sentence that Landlord acted unreasonably, the requested consent or approval shall be deemed to have been granted; however, Landlord shall have no liability whatsoever to Tenant for its
refusal or failure to give such consent or approval. Tenant’s sole remedy for Landlord’s unreasonably withholding, conditioning or delaying consent or approval shall be as provided in this Section 39.5 and in
Section 39.22. 
 Section 39.6 

(A) Tenant represents and warrants that to its actual knowledge (a) Tenant and each person or entity owning an interest in Tenant is
(i) not currently identified on the Specially Designated Nationals and Blocked Persons List maintained by the Office of Foreign Assets Control, Department of the Treasury (“OFAC”) and/or on any other similar list maintained by
OFAC pursuant to any authorizing statute, executive order or regulation (collectively, the 

  
 71 

 
“List”), and (ii) not a person or entity with whom a citizen of the United States is prohibited to engage in transactions by any trade embargo, economic sanction, or other
prohibition of United States Laws, regulation, or Executive Order of the President of the United States, (b) none of the funds of Tenant have been derived from any unlawful activity with the result that this Lease is in violation of Laws, and
(c) Tenant has implemented procedures, and will consistently apply those procedures, to ensure that it is in compliance with Laws. 

(B) Tenant covenants and agrees (a) to comply with all Laws relating to money laundering, anti-terrorism, trade embargos and economic
sanctions, now or hereafter in effect, (b) to immediately notify Landlord in writing if any of the representations, warranties or covenants set forth in this paragraph or the preceding paragraph are no longer true or have been breached,
(c) not to use funds from any “Prohibited Person” (as such term is defined in the September 24, 2001 Executive Order Blocking Property and Prohibiting Transactions With Persons Who Commit, Threaten to Commit, or Support
Terrorism) to make any payment due to Landlord under this Lease and (d) at the request of Landlord, to provide such information as may be requested by Landlord to determine Tenant’s compliance with the terms hereof, provided that Tenant
shall otherwise be required to provide such information to Government Authorities under applicable Law. 
 (C) Tenant hereby acknowledges
and agrees that Tenant’s inclusion on the List at any time during the Term shall be a material default of this Lease. Notwithstanding anything herein to the contrary, Tenant shall not knowingly permit the Premises or any portion thereof to be
used or occupied by any person or entity on the List, and any such use or occupancy of the Premises by any such person or entity shall be a material default of this Lease. 

In connection with this Lease or any proposed assignment of this Lease or sublease, Tenant shall provide to Landlord within thirty
(30) days after request the names of the persons holding an ownership interest in Tenant or any proposed assignee or sublessee, as applicable, if required for purposes of compliance with Presidential Executive Order 13224 (issued
September 24, 2001), as amended. 
 Section 39.7 If Tenant shall remain in possession of the Premises after the Expiration Date,
without the execution by both Tenant and Landlord of a new lease, Tenant, at the election of Landlord, shall be deemed to be occupying the Premises as a Tenant from month-to-month, at a monthly rental equal to (i) for the first thirty
(30) days of such holdover, 150% of the Rental payable during the last month of the Term, and (ii) thereafter during such holdover, 200% of the Rental payable during the last month of the Term, subject to all the other conditions,
provisions and obligations of this Lease insofar as the same are applicable to a month-to-month tenancy. The acceptance of any holdover rental paid by Tenant pursuant to this Section 39.7 shall not preclude Landlord from commencing and
prosecuting a holdover or summary eviction proceeding. 
 Section 39.8 This Lease shall be construed without regard to any presumption
or other rule requiring construction against the party causing this Lease to be drafted. If any words or phrases in this Lease are stricken out or otherwise eliminated, whether or not any other words or phrases have been added, this Lease shall be
construed as if the words or phrases so stricken out or otherwise eliminated were never included in this Lease and no implication or inference shall be drawn from the fact that such words or phrases were stricken out or otherwise eliminated. 

  
 72 

 Section 39.9 Landlord shall make available to Tenant on any directory in the lobby of the
Building which Landlord may install, Tenant’s Share of the total number of listings available, which listings may include subtenants occupying the Premises in accordance with the terms hereof. The initial listing shall be without charge to
Tenant. From time to time, but not more frequently than once every three (3) months, Landlord shall revise the directory to reflect such changes in the listings therein as Tenant may request, and Tenant within thirty (30) days after demand
by Landlord shall pay to Landlord, as Additional Rent, Landlord’s reasonable cost in making each revision that Tenant requests. 

Section 39.10 Intentionally Omitted. 

Section 39.11 If any of the provisions of this Lease, or the application thereof to any person or circumstance, shall, to any extent, be
invalid or unenforceable, the remainder of this Lease, or the application of such provisions to persons or circumstances other than those as to whom or which it is held invalid or unenforceable, shall not be affected thereby and shall remain valid
and enforceable, and every provision of this Lease shall be valid and enforceable to the fullest extent permitted by law. 

Section 39.12 Landlord shall have the right to erect any gate, chain or other obstruction or to close off any portion of the Real
Property to the public at any time to the extent necessary to prevent a dedication thereof for public use, so long as Tenant’s access to the Premises shall not be unreasonably impaired thereby. 

Section 39.13 Landlord and Tenant each hereby represents to the other party that it is not entitled, directly or indirectly, to
diplomatic or sovereign immunity and agrees that in all disputes arising directly or indirectly out of this Lease it shall be subject to service of process in, and the jurisdiction of the courts of, the State of New York. The provisions of this
Section 39.13 shall survive the expiration of this Lease. 
 Section 39.14 This Lease contains the entire agreement between the
parties and all prior negotiations and agreements are merged into this Lease. This Lease may not be changed, abandoned or discharged, in whole or in part, nor may any of its provisions be waived except by a written agreement that (a) expressly
refers to this Lease, and (b) is executed by the party against whom enforcement of the change, abandonment, discharge or waiver is sought. 

Section 39.15 Any apportionment or prorations of Rental to be made under this Lease shall be computed on the basis of a three hundred
sixty (360) day year, with twelve (12) months of thirty (30) days each. 
 Section 39.16 This Lease shall be governed by
the laws of the State of New York without regard to conflict of laws principles. 
 Section 39.17 Each person executing this Lease on
behalf of Landlord and Tenant hereby covenants, represents and warrants that such entity is duly incorporated or duly qualified (if foreign) and is authorized to do business in the State of New York; and that each person executing this Lease on
behalf of such party is an officer or member or partner of such party (or such party’s partner) and that he or she is duly authorized to execute, acknowledge and deliver this Lease (a copy of a resolution to that effect to be supplied to
Landlord by Tenant upon request). 

  
 73 

 Section 39.18 The captions are inserted only as a matter of convenience and for reference
and in no way define, limit or describe the scope of this Lease nor the intent of any provision thereof. 
 Section 39.19 The
covenants, conditions and agreements contained in this Lease shall bind and inure to the benefit of Landlord and Tenant and their respective legal representatives, successors, and, except as otherwise provided in this Lease, their assigns. 

Section 39.20 From and after the date of this Lease, Tenant and Persons Within Tenant’s Control shall maintain the terms and
conditions of this Lease confidential and, without Landlord’s prior written consent, shall neither discuss nor disclose the terms and conditions of this Lease with any tenant or occupant of the Building or with any other person, other than
(i) the Broker, (ii) the attorneys who are representing Tenant in connection with this Lease, (iii) Tenant’s accountants and (iv) any proposed subtenant of the Premises or assignee of this Lease and only if and to the extent
such other parties listed in clauses (i) to (iv) inclusive are informed by Tenant of the confidential nature of this Lease and shall agree to act in accordance with the provisions of this section, or (v) if required to do so to
enforce the terms of this Lease, or as may otherwise be required to be disclosed by Laws or judicial process; provided that, if Tenant is required or requested by legal process to disclose the terms and conditions of this Lease, Tenant shall
provide Landlord with prompt notice of such requirement or request and unless Landlord waives the confidentiality requirements of this Lease, Tenant shall cooperate with Landlord, at Landlord’s cost and expense, in obtaining an appropriate
protective order regarding such disclosure. Tenant acknowledges that a breach or threatened breach of this section will cause irreparable injury and damage to Landlord, and, therefore, agrees that, in addition to any other remedies that may be
available to Landlord, Landlord shall be entitled to an injunction and/or other equitable relief (without the requirement of posting a bond or other security) as a remedy for a breach or threatened breach of this section and to secure its
enforcement. 
 Section 39.21 For the purposes of this Lease and all agreements supplemental to this Lease, unless the context
otherwise requires: 
 (a) The words “herein”, “hereof”, “hereunder” and “hereby” and
words of similar import shall be construed to refer to this Lease as a whole and not to any particular Article or Section unless expressly so stated. 

(b) Tenant’s obligations hereunder shall be construed in every instance as conditions as well as covenants, each separate
and independent of any other terms of this Lease. 
 (c) Reference to Landlord as having “no liability” or being
“without liability” shall mean that Tenant shall not be entitled to terminate this Lease, or to claim actual or constructive eviction, partial or total, or to receive any abatement or diminution of rent, or to be relieved in any manner of
any of its other obligations hereunder, or to be compensated for loss or injury suffered or to enforce any other right or liability whatsoever against Landlord under or with respect to this Lease or with respect to Tenant’s use or occupancy of
the Premises. 

  
 74 

 (d) Reference to “termination of this Lease” or “expiration of
this Lease” and words of like import includes expiration or sooner termination of this Lease and the Term and the estate hereby granted or cancellation of this Lease pursuant to any of the provisions of this Lease or to law. Upon the
termination of this Lease, the Term and estate granted by this Lease shall end at 11:59 p.m. on the date of termination as if such date were the Fixed Expiration Date, and neither party shall have any further obligation or liability to the other
after such termination except (i) as shall be expressly provided for in this Lease, and (ii) for such obligations as by their nature under the circumstances can only be, or by the provisions of this Lease, may be, performed after such
termination, and, in any event, unless expressly otherwise provided in this Lease, any liability for a payment (which shall be apportioned as of such termination) which shall have accrued to or with respect to any period ending at the time of
termination shall survive the termination of this Lease. 
 (e) Words and phrases used in the singular shall be deemed to
include the plural and vice versa, and nouns and pronouns used in any particular gender shall be deemed to include any other gender. 

(f) The rule of “ejusdem generis” shall not be applicable to limit a general statement following or referable to an
enumeration of specific matters to matters similar to the matters specifically mentioned. 
 Section 39.22 If Tenant desires to
determine any dispute between Landlord and Tenant as to the reasonableness of Landlord’s decision to refuse to consent to any Alterations in accordance with the provisions of Article 6 or to any subletting or assignment in accordance
with the provisions of Article 15, such dispute shall be settled and finally determined by arbitration in The City of New York in accordance with the following provisions of this Section. Within five (5) Business Days following the
giving of any notice by Tenant to Landlord stating that it wishes such dispute to be so determined, Landlord and Tenant shall each give notice to the other setting forth the name and address of an arbitrator designated by the party giving such
notice. If either party shall fail to give notice of such designation within said five (5) Business Days, then the arbitrator chosen by the other side shall make the determination alone. The two arbitrators shall designate a third arbitrator.
If the two arbitrators shall fail to agree upon the designation of a third arbitrator within five (5) Business Days after the designation of the second arbitrator, then either party may apply to the Supreme Court of the State of New York or to
any other court having jurisdiction, for the designation of such arbitrator. All arbitrators shall be persons who shall have had at least ten (10) years of continuous experience in the business of owning or managing real estate in the Borough
of Manhattan, The City of New York. The three arbitrators shall conduct such hearings as they deem appropriate, making their determination in writing and giving notice to Landlord and Tenant of their determination as soon as practicable, and if
possible, within five (5) Business Days after the designation of the third arbitrator; the concurrence of any two of said arbitrators shall be binding upon Landlord and Tenant, or, in the event no two of the arbitrators shall render a
concurrent determination, then the determination of the third arbitrator designated shall be binding upon Landlord and Tenant. Judgment upon any award rendered in any arbitration held pursuant to this Section shall be final and binding upon Landlord
and Tenant, whether or not a judgment shall be entered in any court. Each party shall pay its own counsel fees and expenses, if any, in connection with any arbitration under this Section, including the expenses and fees of any arbitrator selected by
it in accordance with the 

  
 75 

 
provisions of this Section, and the parties shall share all other expenses and fees of any such arbitration. The arbitrators shall be bound by the provisions of this Lease, and shall not add to,
subtract from or otherwise modify such provisions. 
 ARTICLE 40 

SECURITY DEPOSIT 

Section 40.1 Tenant has deposited with Landlord on the signing of this Lease the Security Deposit by Letter of Credit (as defined and
further described in Section 40.2), as security for the faithful performance and observance by Tenant of the terms, provisions and conditions of this Lease. Tenant agrees that in the event of the occurrence of an Event of Default,
Landlord may draw upon the Letter of Credit and use, apply or retain the whole or any part of such proceeds, to the extent required for the payment of any Fixed Rent, Escalation Rent, or any other sum as to which Tenant is in default, or for any sum
that Landlord may expend or may be required to expend by reason of the default (including any damages or deficiency accrued before or after summary proceedings or other re-entry by Landlord). If Landlord applies or retains any portion or all of the
proceeds of the Letter of Credit, Tenant shall forthwith restore the amount so applied or retained by delivering an additional or new Letter of Credit so that, at all times, the amount of the Security Deposit shall be the amount set forth on the
Reference Page. Provided there is no uncured default, any balance of the proceeds of the Letter of Credit held by Landlord and not used, applied or retained by Landlord as above provided, and any remaining Letter of Credit, shall be returned to
Tenant after the Expiration Date and after delivery of possession of the entire Premises to Landlord in accordance with the terms of this Lease. 

Section 40.2 Tenant shall deliver to Landlord a clean, irrevocable and unconditional letter of credit (such letter of credit, and any
replacement thereof as provided herein, is called a “Letter of Credit”) issued and drawn upon UBS Financial Services, Inc. (together with the issuer of any replacement Letter of Credit, the “Issuer”), which Letter
of Credit shall have a term of not less than one year, be in form and content satisfactory to Landlord, be for the account of Landlord and be in the amount of the Security Deposit set forth in the Reference Page. The form of letter of credit annexed
to this Lease as Schedule E is satisfactory. The Letter of Credit shall provide that: 
 (1) The Issuer shall pay to Landlord or its
duly authorized representative an amount up to the face amount of the Letter of Credit upon presentation of the Letter of Credit and a sight draft in the amount to be drawn; 

(2) The Letter of Credit shall be deemed to be automatically renewed, without amendment, for consecutive periods of one year each during the
Term, unless the Issuer sends written notice (the “Non-Renewal Notice”) to Landlord by certified or registered mail, return receipt requested, at least thirty (30) days prior to the expiration date of the Letter of Credit, to
the effect that it elects not to have such Letter of Credit renewed; 
 (3) The Letter of Credit delivered in respect of the last year of
the Term shall have an expiration date of not earlier than sixty (60) days after the Fixed Expiration Date; and 
 (4) The Letter of
Credit shall be transferable by Landlord as provided in Section 40.4. 

  
 76 

 Any replacement Letter of Credit shall be issued by a commercial bank or other financial institution approved by
Landlord (which approval shall not be unreasonably withheld, conditioned or delayed) upon which presentation may be made in the City of New York or by facsimile presentation with original to follow which shall have combined capital, surplus and
undivided profits of at least One Billion Dollars ($1,000,000,000) and a financial strength rating of at least “A” and a long-term bank deposit rating of at least “Aa”, as published by Moody’s Investors Services, Inc., or
its successor (collectively, the “Issuer Criteria”). If at any time during the Term, the Issuer does not maintain the Issuer Criteria, then Landlord may so notify Tenant and, unless Tenant delivers a replacement Letter of Credit
from another bank or financial institution meeting the Issuer Criteria within thirty (30) days after receipt of such notice, Landlord may draw the full amount of the Letter of Credit and hold the proceeds as a cash security deposit in
accordance with all Laws. Landlord shall release such proceeds to Tenant upon delivery to Landlord of a replacement Letter of Credit complying with the terms of this Article 40. 

Section 40.3 Landlord, after receipt of the Non-Renewal Notice, shall have the right to draw the entire amount of the Letter of Credit
and to hold the proceeds as a cash Security Deposit. Landlord shall release such proceeds to Tenant upon delivery to Landlord of a replacement Letter of Credit complying with the terms hereof. 

Section 40.4 In the event of the sale or lease or other conveyance of the Building or the Real Property, Landlord shall transfer the
Security Deposit, without charge for such transfer to Landlord, the purchaser, lessee or other transferee, and Landlord shall thereupon be released by Tenant from all liability for the return of such Security Deposit. In such event, Tenant agrees to
look solely to the new Landlord for the return of said Security Deposit. It is agreed that the provisions hereof shall apply to every transfer or assignment made of the Security Deposit to a new Landlord. Tenant shall execute such documents as may
be necessary to accomplish such transfer or assignment of the Letter of Credit. 
 Section 40.5 Tenant covenants that it will not
assign or encumber, or attempt to assign or encumber, the Security Deposit held hereunder, and that neither Landlord nor its successors or assigns shall be bound by any such assignment, encumbrance, attempted assignment, or attempted encumbrance. In
the event that any bankruptcy, insolvency, reorganization or other debtor-creditor proceedings shall be instituted by or against Tenant, its successors or assigns, or any guarantor of Tenant hereunder, the security shall be deemed to be applied to
the payment of the Fixed Rent and Additional Rent due Landlord for periods prior to the institution of such proceedings and the balance, if any, may be retained by Landlord in partial satisfaction of Landlord’s damages. 

Section 40.6 Provided that no Event of Default shall have occurred and then be continuing at any time on or after the third
(3rd) anniversary of the Rent Commencement Date, Tenant may reduce the Security Deposit to the amount of $139,507.50. In no event shall the Security Deposit be further reduced to an amount below $139,507.50. Such reduction(s) shall be effected
by (x) Tenant exchanging a replacement Letter of Credit meeting the requirements of this Article 40 in the reduced amount for the existing Letter of Credit, or (y) the Issuer delivering

  
 77 

 
an amendment to the Letter of Credit reducing the amount thereof to the amount then permitted pursuant to this Section 40 (but which does not otherwise amend or modify same), which
Landlord shall promptly countersign or authorize in writing if required by the Issuer. 
 ARTICLE 41 

ROOF INSTALLATIONS 

Section 41.1 Tenant shall have the right to install, remove, replace, repair, maintain and operate on the available space on the roof of
the Building, at Tenant’s sole cost and expense (and by using Landlord’s designated contractor), a sixteen (16”) inch DSL satellite dish, antenna and support equipment (hereinafter collectively referred to as the
“Installations”), at a mutually agreeable location reasonably suitable for the installation and operation thereof, subject to all of the terms, covenants and conditions of this Lease (including Article 6), and subject to
Landlord’s prior written approval, including, without limitation, approval as to size, weight, location and method of attachment, which approval shall not be unreasonably withheld, conditioned or delayed, and the approval of the Landmarks
Preservation Commission. Landlord’s approval shall also be required for modifications to, and the removal of, the Installations, which approval shall not be unreasonably withheld, conditioned or delayed. In connection with Tenant’s
installation, removal, replacement, repair, maintenance and operation of its Installations, Tenant shall comply with all Laws and shall procure, maintain and pay for all permits and licenses required therefor, including all renewals thereof.
Landlord shall cooperate with Tenant to assist Tenant in obtaining such permits and licenses. The parties agree that Tenant’s use of the roof of the Building is a non-exclusive use and Landlord may permit the use of any other portion of the
roof to any other person, firm or corporation for any use, including the installation of other antennas, generators and/or communications systems. Tenant shall ensure that its use of the roof does not impair such other person’s, firm’s or
corporation’s data transmission and reception via their respective antennas and support equipment, if any, and Landlord agrees that it shall require other tenants or occupants of the Building requesting use of the roof to make a similar
covenant in connection therewith. Tenant, at its sole cost and expense, shall install any screening device reasonably requested by Landlord at any time to ensure that the Installations cannot be viewed or seen by the public and, if such screening
device is installed, it shall be deemed to be an Installation under this clause. 
 Section 41.2 In no event shall the maximum level of
emissions from the Installations exceed a reasonable portion of the total emissions allowable for the Building under applicable Laws, taking into account the number of rooftop installations at the Building. 

Section 41.3 Tenant shall pay for all electrical service required for Tenant’s use of the Installations in accordance with
Article 4 of this Lease. Tenant shall be responsible for connecting the Installations and the Premises by core drilling and, if necessary, installing a conduit in the Building shafts and risers, and Landlord shall provide Tenant, at no cost
to Tenant, with all reasonable and non-exclusive access to such shafts and risers for Tenant’s installation, removal, replacement, repair, maintenance and operation therein of lines, cables and other installations. 

Section 41.4 Tenant, at Tenant’s sole cost and expense, shall promptly repair any and all damage to the roof of the Building and to
any part of the Building caused by or resulting from 

  
 78 

 
the installation, maintenance and repair, operation or removal of the Installations erected or installed by Tenant pursuant to the provisions of this Article 41. Tenant further covenants
and agrees that the Installations and any related equipment erected or installed by Tenant pursuant to the provisions of this Article 41 shall be erected, installed, repaired, maintained and operated by Tenant at the sole cost and expense of
Tenant and without charge, cost or expense to Landlord. 
 Section 41.5 The Installations and related equipment installed by Tenant
pursuant to the provisions of this Article 41 shall be Tenant’s Property, and, upon the expiration or earlier termination of the Term of this Lease shall be removed by Tenant, at Tenant’s sole cost and expense and Tenant shall
repair any damage to the roof of the Building, or any other portion or portions of the Building caused by or resulting from said removal. 

Section 41.6 Landlord may require Tenant to relocate the Installations and related equipment to another reasonably suitable portion of
the roof upon thirty (30) days’ notice to Tenant or to remove the Installations if their existence would constitute a violation of any Laws. 

ARTICLE 42 
 OPTION TO RENEW

 Section 42.1 Provided that both at the time of the exercise of the Renewal Option (as hereinafter defined) and at the time of
the commencement of the Renewal Term (as hereinafter defined): (i) this Lease shall be in full force and effect; (ii) there shall not then be existing an Event of Default under this Lease; and (iii) Tenant (and its affiliates) are in
physical occupancy of the entire Premises, Tenant shall have one option to extend the Term of this Lease (the “Renewal Option”) for a period of five (5) years (the “Renewal Term”). The Renewal Term shall
commence on the day following the Fixed Expiration Date. The Renewal Option shall be exercisable by written notice (the “Renewal Notice”) to Landlord given not earlier than eighteen (18) months, nor later than twelve
(12) months, prior to the Fixed Expiration Date. Notwithstanding the first sentence of this Section 42.1, Landlord, in its sole discretion, may waive any default by Tenant and no such default may be used by Tenant to negate the
effectiveness of Tenant’s exercise of the Renewal Option. The Renewal Term shall constitute an extension of the Term of this Lease and shall be upon all of the same terms and conditions as the existing Term, except that (A) during the
Renewal Term there shall be no further option to renew the Term of this Lease, (B) Landlord shall not be required to furnish any materials or perform any Landlord’s Work or other work to prepare the Premises for Tenant’s continued
occupancy during the Renewal Term and Landlord shall not be required to make a Tenant Improvement Allowance or to reimburse Tenant for any Alterations made or to be made by Tenant during or in preparation of the Renewal Term, and (C) the Fixed
Rent for the Renewal Term shall be payable at a rate per annum equal to the Fair Market Value of the Premises as of the first day of the Renewal Term. During the Renewal Term, all Escalation Rent that Tenant is obligated to pay under Article
3 of this Lease during the existing Term hereof shall continue without interruption, it being the intention of the parties hereto that the Renewal Term shall be deemed a part of and continuation of the existing Term of this Lease, except that
the Base Tax Factor for the Renewal Term shall be the Taxes payable for the Tax Year commencing on July 1, 2020 and the Base Operating Factor shall be the Operating Expenses paid or incurred with respect to the Operating Year commencing on
January 1, 2020. 

  
 79 

 Section 42.2 If Tenant has given the Renewal Notice in accordance with
Section 42.1, the parties shall endeavor to agree upon the Fair Market Value of the Premises, as of the commencement date of the Renewal Term. In the event that the parties are unable to agree upon the Fair Market Value for the Renewal
Term within six months prior to the first day of the Renewal Term then the same shall be determined as follows. Landlord shall notify Tenant of Landlord’s good faith determination of the Fair Market Value, which shall constitute the maximum
that Landlord can claim is the Fair Market Value of the Premises for the applicable Renewal Term in any arbitration thereof (“Landlord’s Maximum Determination”). Within 30 days after Landlord shall have given Tenant
Landlord’s Maximum Determination (time being of the essence as to Tenant’s obligation to give Landlord Tenant’s Minimum Determination by such date), Tenant shall notify Landlord whether Tenant disputes Landlord’s Maximum
Determination and, if Tenant disputes Landlord’s Maximum Determination, Tenant shall set forth in such notice Tenant’s good faith determination of the Fair Market Value of the Premises for the applicable Renewal Term, which shall
constitute the minimum that Tenant can claim is the Fair Market Value for the Premises for the applicable Renewal Term in any arbitration thereof (“Tenant’s Minimum Determination”). If Tenant fails to dispute Landlord’s
Maximum Determination or to set forth Tenant’s Minimum Determination within the time period set forth above (time being of the essence as to Tenant’s obligation to give Landlord Tenant’s Minimum Determination by such date), then
Tenant shall be deemed to have accepted Landlord’s Maximum Determination as the Fair Market Value for the Renewal Term. 

Section 42.3 If Tenant disputes Landlord’s determination of Fair Market Value, and Landlord and Tenant fail to agree as to the
amount thereof within 30 days after the giving of Tenant’s Minimum Determination, then the dispute shall be resolved by arbitration as set forth below. If the dispute shall not have been resolved on or before the first day of the Renewal Term,
then pending such resolution, Tenant shall pay, as Fixed Rent for the Renewal Term, an amount equal to Landlord’s Maximum Determination. If such resolution shall be in favor of Tenant, then within 30 days after the final determination of Fair
Market Value for the Renewal Term, Landlord shall refund to Tenant any overpayment. Any dispute as to Fair Market Value shall be determined as follows. A senior officer of a recognized New York City leasing brokerage firm (the “Baseball
Arbitrator”) shall be selected and paid for jointly by Landlord and Tenant. If Landlord and Tenant are unable to agree upon the Baseball Arbitrator, then the same shall be designated by the American Arbitration Association
(“AAA”). The Baseball Arbitrator selected by the parties or designated by the AAA shall not have been employed by Landlord or Tenant during the previous five-year period and shall have at least ten years experience in the leasing of
office space in Manhattan in the vicinity of the Building. Landlord and Tenant shall each submit to the Baseball Arbitrator and to the other its determination of the Fair Market Value for the applicable Renewal Term, as set forth above, which need
not be Landlord’s Maximum Determination or Tenant’s Minimum Determination. The Baseball Arbitrator shall determine which of the two rent determinations more closely represents the Fair Market Value for the Renewal Term. The Baseball
Arbitrator may not select any other rental value for the Renewal Term other than one submitted by Landlord or Tenant. The determination of the Baseball Arbitrator shall be binding upon Landlord and Tenant and shall serve as the Fixed Rent payable
for the Renewal Term. After a determination has been made of the Fair Market Value, the parties shall execute and deliver an instrument setting forth the Fixed Rent for the Renewal Term, but the failure to so execute and deliver any such instrument
shall not affect the determination of such Fixed Rent in accordance with this Article 42. 

  
 80 

 ARTICLE 43 

RIGHT OF FIRST OFFER 

Section 43.1 As used herein, 

“Available” means, as to the ROFO Space, that such space is vacant and free of any present or future possessory right or
option then existing in favor of any third party. Tenant acknowledges that Tenant shall have no rights under this Article 43 with respect to particular ROFO Space unless and until Landlord has first leased such ROFO Space after the date of
this Lease. Tenant further acknowledges and agrees that the ROFO Space is presently vacant and that Landlord may lease all or any of such space on whatever terms Landlord may deem appropriate, and that the availability of the ROFO Space shall be
subject to any rights of first offer or expansion granted to other tenants in the Building as of the date of this Lease as more particularly set forth on Schedule J annexed hereto. Tenant further acknowledges and agrees that Tenant shall have
no rights under this Article 43 with respect to particular ROFO Space until the end of the twenty-fifth (25th) month after the Rent Commencement Date. In addition, ROFO Space shall not be deemed Available if Landlord is negotiating a
renewal or extension, or a new lease, with an existing occupant of the ROFO Space, and Landlord shall be free to enter into any such agreement with such occupant at any time. 

“ROFO Space” means any space on the second (2nd), fourth (4th) or fifth (5th) floors of the Building, provided that ROFO Space may include other space in the Building marketed by Landlord together
with the ROFO Space, even if such other space is not on the second, fourth or fifth floors of the Building. 
 Section 43.2 (A)
Provided that (i) this Lease shall be in full force and effect, (ii) there shall not then be existing an Event of Default under this Lease, (iii) Tenant (and its affiliates) shall then physically occupy the entire Premises, and
(iv) as of the Anticipated ROFO Inclusion Date (as hereinafter defined), there shall be at least five (5) years remaining in the Term or the Renewal Term (if Tenant shall have exercised its Renewal Option); then from and after the end of
the twenty-fifth (25th) month after the Rent Commencement Date, if as and when, from time to time during the Term, all or any portion of the ROFO Space becomes, or Landlord becomes aware that all or any portion of the ROFO Space will become,
Available, then Landlord, as soon as practicable, shall give Tenant notice (a “ROFO Notice”) thereof, specifying (A) Landlord’s good faith determination of the Fair Market Value for such ROFO Space, which shall constitute
the maximum thereof Landlord can claim as the Fair Market Value for such space in any arbitration thereof (“Landlord’s Maximum ROFO Determination”), (B) the date or estimated date that such ROFO Space has or shall become
Available (the “Anticipated ROFO Inclusion Date”), and (C) a description of such ROFO Space. 
 (B) Provided that on
the date that Tenant exercises a ROFO Space Option (as hereinafter defined) and on the applicable ROFO Space Inclusion Date (as hereinafter defined), (i) this Lease shall be in full force and effect, (ii) there shall not then be existing
an Event of Default under this Lease, (iii) Tenant (and its affiliates) shall then physically occupy the entire Premises, and (iv) at the time that Tenant exercises the ROFO Space Option and on the ROFO Space Inclusion Date, there shall be
at least five (5) years remaining in the Term or the Renewal Term (if Tenant shall have exercised its Renewal Option), Tenant shall have the option with 

  
 81 

 
respect to each portion of the ROFO Space covered by a ROFO Notice (a “ROFO Space Option”), exercisable by notice (a “ROFO Acceptance Notice”) given to Landlord
on or before the date that is ten (10) Business Days after the giving of such ROFO Notice (time being of the essence with respect to Tenant’s obligation to give the ROFO Acceptance Notice by such date) to include such ROFO Space (and not
less than all of such ROFO Space) in the Premises for a term ending on the Fixed Expiration Date. Tenant shall notify Landlord in its ROFO Acceptance Notice whether Tenant accepts or disputes Landlord’s Maximum ROFO Determination, and if Tenant
disputes Landlord’s Maximum ROFO Determination, the ROFO Acceptance Notice shall set forth Tenant’s good faith determination of the Fair Market Value for such ROFO Space, which shall constitute the minimum that Tenant can claim as the Fair
Market Value for such space in any arbitration thereof (“Tenant’s Minimum ROFO Determination”). If Tenant fails to object to Landlord’s Maximum ROFO Determination in the ROFO Acceptance Notice and to set forth therein
Tenant’s Minimum ROFO Determination, then Tenant shall be deemed to have accepted Landlord’s Maximum ROFO Determination as the Fair Market Value for such ROFO Space. 

(C) Notwithstanding anything to the contrary contained in this Section 43.2, if at any time after the end of the twenty-fifth
(25th) month after the Rent Commencement Date all or any portion of the ROFO Space becomes, or Landlord becomes aware that all or any portion of the ROFO Space will become, Available when less than five (5) years but more than eighteen
(18) months are then remaining in the Term, Landlord nevertheless shall give the ROFO notice to Tenant and Tenant nevertheless shall have the right to exercise the ROFO Space Option if, together with the ROFO Acceptance Notice, Tenant shall
exercise its Renewal Option (in which event the limitation set forth in Section 42.1 as to the time when the Renewal Notice may be given shall not apply). 

Section 43.3 If Tenant timely delivers a ROFO Acceptance Notice, then, on the date on which Landlord delivers vacant and broom-clean
possession of the applicable ROFO Space to Tenant (the “ROFO Space Inclusion Date”), such ROFO Space shall become part of the Premises, upon all of the terms and conditions set forth in this Lease, except (i) the Fixed Rent for
the ROFO Space shall be equal to the Fair Market Value, without an abatement of Fixed Rent, (ii) Landlord shall not be required to perform any Landlord’s Work or any other work, pay a Tenant Improvement Allowance or any other amount, or
render any services to make the Building or such ROFO Space ready for Tenant’s use or occupancy, and Tenant shall accept such ROFO Space in its “as is” condition on the applicable ROFO Space Inclusion Date, (iii) Tenant shall be
obligated to pay Escalation Rent for the ROFO Space pursuant to Article 3 (but with current base years), (iv) Tenant shall be obligated to deposit with Landlord an additional Security Deposit with respect to the ROFO Space commensurate
with the existing Security Deposit and (v) as may be otherwise set forth above. 
 Section 43.4 If in any ROFO Acceptance Notice
Tenant disputes Landlord’s determination of Fair Market Value, and Landlord and Tenant fail to agree as to the amount thereof within thirty (30) days after the giving of the ROFO Acceptance Notice, then the dispute shall be resolved by
arbitration as set forth in Section 42.3, except (i) Tenant’s Minimum ROFO Determination shall be substituted for Tenant’s Minimum Determination and Landlord’s Maximum ROFO Determination shall be substituted for
Landlord’s Maximum Determination. If the dispute shall not have been resolved on or before the applicable ROFO Space Inclusion Date, then pending such resolution, Tenant shall pay, as Fixed Rent for the applicable ROFO Space, an

  
 82 

 
amount equal to Landlord’s Maximum ROFO Determination. If such resolution shall be in favor of Tenant, then within 30 days after the final determination of Fair Market Value, Landlord shall
refund to Tenant any overpayment. 
 Section 43.5 If Landlord is unable to deliver possession of any ROFO Space to Tenant for any
reason on or before the applicable Anticipated ROFO Inclusion Date, the applicable ROFO Space Inclusion Date shall be the date on which Landlord is able to so deliver possession and Landlord shall have no liability to Tenant therefor and this Lease
shall not in any way be impaired. This Section 43.5 constitutes “an express provision to the contrary” within the meaning of Section 223-a of the New York Real Property Law and any other law of like import now or hereafter
in effect. Notwithstanding the foregoing, in the event that Landlord is unable to deliver possession of any ROFO Space to Tenant for any reason within six (6) months after the applicable Anticipated ROFO Inclusion Date, (x) Tenant shall
have the right to revoke its ROFO Acceptance Notice, and in the event of such revocation, Tenant shall have no further rights or obligations with respect thereto and (y) the terms and conditions of this Article 43 shall remain in full
force and effect. Tenant hereby acknowledges and agrees that such rescission right shall be Tenant’s sole and exclusive remedy if the ROFO Space Inclusion Date shall not have occurred within six (6) months after the applicable Anticipated
ROFO Inclusion Date, and that Landlord shall have no other liability to Tenant for failure of the ROFO Space Inclusion Date to occur. 

Section 43.6 If Tenant fails timely to give a ROFO Acceptance Notice, then Landlord may enter into one or more leases of the applicable
ROFO Space (or any portion thereof) with third parties on such terms and conditions as Landlord shall determine. 
 Section 43.7
Promptly after the occurrence of a ROFO Space Inclusion Date, Landlord and Tenant shall confirm the occurrence thereof and the inclusion of the applicable ROFO Space in the Premises by executing an instrument reasonably satisfactory to Landlord and
Tenant; provided that failure by Landlord or Tenant to execute such instrument shall not affect the inclusion of the applicable ROFO Space in the Premises in accordance with this Article 43. 

ARTICLE 44 
 USE OF ROOF

 Section 44.1 Landlord contemplates that a portion of the roof of the Building shall be used for a terrace with elevator access,
containing wood decking, white pavers and metal and wood pergola. To the extent Landlord maintains such terrace and makes its use available to tenants in the Building generally, Tenant shall have the non-exclusive right to use such terrace but
strictly in accordance with such rules, regulations, security procedures, insurance requirements and payment terms as Landlord adopts on a Building-wide basis. 

ARTICLE 45 
 SELF-HELP 

Section 45.1 Provided that no monetary or material, non-monetary default under this Lease is continuing, subject to the notice
requirements set forth below, in the event Tenant advises Landlord in writing that Tenant claims Landlord has failed to perform its obligations 

  
 83 

 
with respect to the repair and maintenance of the DX Unit in accordance with the express terms of Article 7 (collectively, the “DX Maintenance Obligations”), Tenant shall
have the right to remedy such Landlord failure provided that such failure by Landlord of the DX Maintenance Obligations adversely affects Tenant’s ability to conduct Tenant’s normal business operations in at least 5,000 rentable square
feet of the Premises. 
 Section 45.2 Tenant’s right to remedy the foregoing DX Maintenance Obligations shall (x) arise
immediately in case of an emergency whereby Tenant believes, in good faith, there is (i) imminent threat of physical injury to persons or (ii) imminent threat of damage (other than a de minimis nature) to property that reasonably mandates
an immediate response, and (y) in all other cases arise only after Tenant shall have first delivered to Landlord written notice of such failure as set forth below. If Landlord fails to commence to remedy a failure to perform the DX Maintenance
Obligations within fifteen (15) days after delivery of Tenant’s notice, Tenant may deliver a second written notice of such failure to Landlord in 18 point print stating: “LANDLORD HAS FAILED TO PERFORM ITS DX MAINTENANCE OBLIGATIONS
UNDER ARTICLE 7 OF THE LEASE. IF LANDLORD FAILS TO COMMENCE TO REMEDY LANDLORD’S FAILURE TO PERFORM SUCH OBLIGATIONS WITHIN FIVE (5) BUSINESS DAYS, TENANT INTENDS TO EXERCISE ITS RIGHT OF SELF-HELP UNDER ARTICLE 45 OF THE LEASE,” and
if Tenant delivers such second notice and Landlord fails to commence such remedy within such five (5) Business Day period and thereafter diligently pursue such remedy, then Tenant shall have the right to remedy such failure as provided above.
Notwithstanding the time periods described above, Landlord shall use good faith efforts to commence the DX Maintenance Obligations as soon as commercially practicable. If Tenant performs any of Landlord’s DX Maintenance Obligations, Landlord
shall reimburse Tenant for its reasonable out-of-pocket costs of performance within thirty (30) days after a statement is given to Landlord of the amount of such costs and the parties to which such payments have been made, unless Landlord
notifies Tenant that Landlord disputes either the propriety of Tenant’s action and/or that the costs incurred by Tenant were excessive. 

*        *        * 

[Remainder of Page Intentionally Left Blank; Signature Page Follows.] 

  
 84 

 IN WITNESS WHEREOF, Landlord and Tenant have duly executed this Lease as of the day and year
first above written. 
  

					
	LANDLORD:
	
	RFL 160 FIFTH LLC, a Delaware limited liability company
		
	By:	 	 /s/ Aby Rosen

		 	Name:	 	 Aby Rosen

		 	Title:	 	 Member

	
	TENANT:
	
	FORRESTER RESEARCH, INC., a Delaware corporation
		
	By:	 	 /s/ Michael Doyle

		 	Name:	 	 Michael Doyle

		 	Title:	 	 Chief Financial Officer

	
	Tenant’s Federal Employer Identification Number
	
	 04-27977789

  
 85 

 SCHEDULE A 

Floor Plan 
  

 
 ALL AREAS, DIMENSIONS AND CONDITIONS ARE APPROXIMATE. 

  
 A-1 

 SCHEDULE B 

Building Rules & Standards For Alterations 

TABLE OF CONTENTS 
  

							
	 	 	 	  	Page	 
		
	 Tenant’s Responsibilities prior to any Alteration Work
	  	 	B-2	  
			
	 1.
	 	 Landlord’s Consent
	  	 	B-2	  
	 2.
	 	 Construction Plans and Applications
	  	 	B-2	  
		 	 A Formatting Guidelines:
	  	 	B-2	  
		 	 B. Architectural Drawings and Specifications
	  	 	B-3	  
		 	 C. Mechanical Engineering Drawings and Specifications
	  	 	B-5	  
		 	 D. Electrical Engineering Drawings and Specifications
	  	 	B-6	  
		 	 E. Plumbing Engineering Drawings and Specifications
	  	 	B-6	  
		 	 F. Fire Suppression (Sprinkler) System Engineering Drawings and Specifications
	  	 	B-7	  
		 	 G. Fire and Life Safety System Engineering Drawings and Specifications
	  	 	B-7	  
		 	 H. Structural Engineering Drawings and Specifications
	  	 	B-8	  
		 	 I. Card Access/Security Cameras Drawings and Specifications
	  	 	B-8	  
	 3.
	 	 Permits
	  	 	B-9	  
	 4.
	 	 Contractor Qualifications
	  	 	B-9	  
	 5.
	 	 Insurance and Indemnification
	  	 	B-10	  
		
	 Tenant’s Responsibilities during Construction of Alterations
	  	 	B-12	  
			
	 1.
	 	 Permissible Work Periods and Work in Non-Tenant Areas
	  	 	B-12	  
	 2.
	 	 Protection of Building
	  	 	B-12	  
	 3.
	 	 Demolition and Construction
	  	 	B-12	  
	 4.
	 	 Controlled Inspections
	  	 	B-13	  
	 5.
	 	 Landlord’s Review of Work
	  	 	B-13	  
	 6.
	 	 Inquiries and Submissions
	  	 	B-13	  
	 7.
	 	 Storage of Materials and Tools
	  	 	B-13	  
	 8.
	 	 Building Construction Services
	  	 	B-13	  
	 9.
	 	 Prohibited Activities
	  	 	B-14	  
	 10.
	 	 Completion Certificates & Completion of Work
	  	 	B-14	  
	 11.
	 	 As-Built Drawings and Specifications
	  	 	B-14	  
	 12.
	 	 Update of Building’s Drawings
	  	 	B-14	  
	 13.
	 	 Contractor’s Rules and Regulations
	  	 	B-14	  
	 Forms
	 		  	 	B-6	  
	 PARTIAL RELEASE AND WAIVER OF LIENS
	  	 	B-6	  
	 FINAL RELEASE AND WAIVER OF LIENS
	  	 	B-8	  

  
 B-1 

 The terms “Decorative Alterations” and
“Alterations” and other capitalized terms not defined in the Building Rules and Building Standards for Alterations (the “Standards”) shall have the respective meanings ascribed to them in the Lease
to which this Schedule B is annexed or incorporated by reference. Tenant shall comply with these Standards in addition to all other provisions set forth in or referred to in the Lease. The Standards shall not be
construed as limiting or otherwise modifying the terms and conditions of any consent to Tenant’s work. These Building Standards and Rules for Alterations may be revised by Landlord from time to time. Tenant is responsible for all
associated costs and or fees in connection with Alteration Work unless otherwise specified in the Lease, including but not limited to (subject to the provisions of the Lease) third party expenses incurred by Landlord associated with reviewing
Tenant’s submission requesting Landlord’s Consent. 
 Tenant’s Responsibilities prior to any Alteration Work

 1. Landlord’s Consent: Except as otherwise provided in the Lease, prior to making any Alterations, Tenant is required to obtain
Landlord’s written approval as set forth in the Lease (“Consent”) to the Construction Plans and Applications outlined below. Prior to making any Decorative Alterations, Tenant is required to notify Landlord thereof in
accordance with the Lease. In order to obtain Landlord’s Consent, when required by the Lease, Tenant shall submit Construction Plans and Applications sufficient to fully define the work proposed in order for the Landlord to provide their
consent as well as update their records. The procedure for Landlord’s consent is defined in Article 6 of the Lease; Tenant shall follow these guidelines in submitting for Approvals and verification process. No work shall proceed without
receiving Landlord’s consent. Landlord reserves the right to stop any work being performed by the Tenant’s General Contractor and or sub-contractors that does not have written consent, if such consent is required by the Lease. 

2. Construction Plans and Applications: All Design and Construction must conform to the current Building Codes and Zoning Requirement as
issued by the authorities having jurisdiction. In all cases of Alterations, the Plans and Applications must be submitted to the Building Manager who will distribute them to the appropriate parties for review and/or approval, if applicable.
Landlord’s written approval will be issued in the timeline provided for in Article 6 of the Lease. The plans should follow the following guidelines: 

A. Formatting Guidelines: 
  

	 	(A)	All plans must be drawn at either 1/8” or 1/4” per foot scale; details must be of sufficient scale to show complete information. 

 

	 	(B)	All tenant alteration drawings submitted must be complete. Landlord will not review drawings unless issued as a complete set. 

  

	 	(C)	All final drawings and “As-Built” drawings shall be submitted on AutoCAD format to the Building Management Office. 

  

	 	(D)	Drawings must be minimum size of 18” x 24”. 

  
 B-2 

	 	(E)	All plans shall have title block showing the following: 

  

	 	(1)	Building address and floor number; 

  

	 	(2)	Name of Tenant; 

  

	 	(3)	Scale and date; 

  

	 	(4)	Name, address and telephone number of architect or designer and engineers; 

  

	 	(5)	Numbering for all sheets; and 

  

	 	(6)	Revisions and all changes to plans noted in revision box (indicating the extent of changes and date). 

  

	 	(F)	Drawings must show all existing conditions, i.e., walls, doors, columns, lights, switches, electric and telephone outlets, as well as: 

 

	 	(1)	Indicate all work to remain; 

  

	 	(2)	Show existing work to be removed; 

  

	 	(3)	Add new work on separate page; 

  

	 	(4)	Provide legend of material covering all new and existing work, indicating location types, sizes and fire ratings of all partitions of any type of material and construction 

 

	 	(5)	Provide plot plan showing location of work, public corridors, Building stairs and elevators. 

  

	 	(G)	All new work, partitions, doors, electrical and telephone outlets must be fully dimensioned. Aligning work with existing work is permitted; however, no dimensions should be given from work that is to be
demolished. Where possible, dimensions should be given from existing walls, column faces, or centerline of window mullions. Drawings must indicate whether dimensions are from partition face or partition centerline. 

B. Architectural Drawings and Specifications: Must include at a minimum, but not be limited to the following: 

 

	 	(A)	Construction Plan fully dimensioned, including the location, types, sizes and fire ratings of all partitions and doors of any type of material and construction. 

 

	 	(1)	Partitions are permitted perpendicular to the exterior wall, no partitions should block the perimeter windows. 

  

	 	(2)	No mechanical fastening of walls to the perimeter fin tube radiation where they intersect each other. 

  
 B-3 

	 	(3)	All Demising partitions must be acoustically lined. 

  

	 	(4)	All corridor partitions and doors must comply with the latest codes. 

  

	 	(B)	Door and Hardware Schedule including the location, types, sizes, fire ratings and finishes of all door frames, doors and door saddles of any type, and all associated hardware including types, manufacturer, model
numbers and finishes of all hardware. All fail-safe hardware must be compatible with the building’s fire alarm system. 

  

	 	(C)	Glass and Glazing Schedule Glass and glazing components shall include all windowed doors, sidelights, pass-through, clear stories and framing, including the types, sizes,
thickness, fire ratings and finishes. 

  

	 	(D)	Reflected Ceiling Plan fully dimensioned and coordinated with the other disciplines, including the switching arrangements for lighting, all lighting fixtures, fire and life safety devices, sprinkler heads, air
conditioning diffusers and/or return grilles. The drawing shall include the ceiling types throughout the Premises including the manufacturer, style and/or model numbers and finishes of any acoustical ceiling systems, including main bars, grids and
molding. 

  

	 	(E)	Power, Fire System, Telephone and Communication Plan including all wall mounted electrical power outlets, whether ganged or separately circuited, specifying type, style, color and finish of outlets and cover
plates, mounting positions and heights. This drawing shall include all fire alarm connection. This drawing shall show all telephone and communication outlets including manufacturer, style, color and finish of cover plates, and mounting positions and
heights. 

  

	 	(F)	Finish Plan including all wall, floor, base and trim finishes throughout the Premises. 

  

	 	(1)	Furniture, carpeting and wall covering must be certified nonflammable and bear the Underwriters’ Laboratory Approval. 

  

	 	(G)	Details of any type, required to understand the type and quality of the various components of the various installations. As example but not limited to: 

 

	 	(1)	Waterproofing of all toilet rooms, pantries with dishwashers or water service with a membrane waterproofing over the entire room and up all partitions 4”. 

 

	 	(2)	Built-in woodworking and cabinetry constitute Alterations and must be constructed of fireproof materials and meet applicable codes. A copy of the material certificates indicating flame spread, etc., must be submitted to
Landlord. 

  

	 	(3)	Penetrations through the floor slab must be properly fire safed or patched with concrete through the full penetration. 

  

	 	(4)	Window Shades shall conform to the Building Standards (i.e., shades shall be purchased through the Building Window treatment Contractor). No other window treatments are permitted. Replacement, repair and cleaning
of window shades shall be coordinated and performed by Manager at the sole cost of the Tenant. 

  

	 	(5)	Public Toilets are not to be altered in any way unless previously authorized per the Lease (except that Tenant shall have the right in its discretion to change the column covers). 

  
 B-4 

	 	(H)	Specifications as required for the complete implementation of the work. 

  

	 	(I)	Building Department Plan and Note Sheets required for filing and permit acquisition including a plot/key plan, applicable D.O.B. Notes, partitions and ceiling details, a construction legend, ADA handicap
maneuvering clearances and plumbing fixture elevations and sections. 

  

	 	(J)	Demolition Plan to the extent necessary to obtain a permit and to ensure that the bidding general contractors/contractors understand the scope and limits of the required demolition and removals. All abandoned or
unused cabling, raceways, sheet metal, ductwork, conduit, pipes, etc., shall be removed back to there point of origin. Active systems shall be capped appropriately. Abandonment in-place is not permitted. 

C. Mechanical Engineering Drawings and Specifications: Must include at a minimum, but not be limited to the following: 

 

	 	(A)	Plan layout and details showing changes and/or additions to the base building heating, ventilating and air conditioning systems servicing the Premises. Include sheet metal drawings, equipment specifications,
piping if applicable and control diagrams. Clearly indicate the method proposed to accomplish the required ventilation index and meet the requirements of the New York State Energy Conservation Construction Code (as amended), and any other
requirements covering this Work. 

  

	 	(B)	Specifications as required for the complete implementation of the Work. 

  

	 	(C)	Supplemental air conditioning system(s) can not be installed without Landlord’s Consent (written permission, which shall not be unreasonably withheld or delayed), unless permission was previously granted in
the Lease. Where required, Tenant shall submit a complete design indicating type of system, equipment specifications, sheet metal drawings, piping if applicable, controls diagrams. The design is to include the following design and installation
criteria: 

  

	 	(1)	Intentionally omitted. 

  

	 	(2)	Tenant shall engage Landlord’s Class “E” Fire Alarm System Vendor at Tenant’s sole expense for the installation of additional devices/points and modifying and reprogram the system as required by the
additional equipment. Tenant shall also enter into “Turn Key” agreement for the term of the Lease to maintain and service the added devices/points due to the additional equipment. 

  
 B-5 

	 	(3)	Intentionally omitted. 

  

	 	(4)	That the system modifications must be demonstrated as operable in the presence of the Consulting Engineer, the Building’s Chief Engineer, the Building Manager and/or his or her designee. Tenant to provide notice of
the tests to all parties at least 72 hours in advance; all tests are to be performed after normal business hours in order not to disturb other Tenants of the Building. 

D. Electrical Engineering Drawings and Specifications: Must include at a minimum, but not be limited to the following: 

 

	 	(A)	Lighting Plan indicating fully labeled circuiting. Connections must be concealed and not exceed three feet in length for motors and six feet in length for lighting fixtures. 

 

	 	(B)	Telephone and Communications Plan. All wire within the Premises shall be run as plenum rated cable and comply with code. Fire and Life Safety System wiring shall not be bundled with any other wiring.

  

	 	(C)	Tenant Power Plan indicating fully labeled circuiting. 

  

	 	(D)	Single-line diagram of the Tenant’s electrical distribution from the point of connection to the existing buss duct(s) or power riser(s) up to and including all tenant distribution panels. 

 

	 	(E)	Panel Schedules including accurate phase balance calculations. All panels must be properly grounded, phase balanced and tagged. 

 

	 	(F)	Specifications as required for a complete implementation of the Work. 

  

	 	(G)	Calculations of entire electrical load expressed in resultant watts per square foot. 

E. Plumbing Engineering Drawings and Specifications: Must include at a minimum, but not be limited to the following: 

 

	 	(A)	Plans showing all proposed modifications and/or additions to the Building’s domestic hot and cold water systems and domestic waste and vent systems must be shown, including all points of connection to the
water, waste and vent risers. Work to be done in any ceilings in any other tenant spaces or in the common areas must be specified to be installed on overtime. 

  

	 	(1)	Domestic Water System: Cold and hot domestic water piping from pump discharge to and including any main risers must be type-K copper tubing of proper pressure rating with brazed or silver soldered fittings.
Branch piping must be type-K copper tubing with soldered connections (95/5 - no lead). Valves must be compatible in pressure rating and material, and the piping materials and must not cause the formation of galvanic corrosion Only Apollo ball valves
may be used on three-inch piping or smaller. Only Building standard high-performance Grinnell butterfly valves may be used in piping over three inches. 

  
 B-6 

	 	(2)	Hot Water System: Tenant may not connect to the buildings hot water systems for private bathrooms, kitchen/pantry, etc. Tenant may install “instant hot system” similar to REMAX Model SP2412 having a 33
degree Fahrenheit rise at 5 GPM connected to the tenant electrical panel, or may use a dedicated tank type hot water heater suitably sized with overflow pan and leak detector. The leak detector should be connected to the building BMS.

  

	 	(3)	Waste and vent piping must be cast iron or no-hub connections. 

 F. Fire Suppression
(Sprinkler) System Engineering Drawings and Specifications: Must include at a minimum, but not be limited to the following: 
  

	 	(A)	Plans showing complete system layout, indicating type, size and location of piping and heads; including the location of the hydraulically most remote 1,500 square foot area as required by code. 

 

	 	(B)	All hydraulic calculations inclusive of identifying any changes needed to the floor PRV setting and the scope shall include any adjustment of the PRV as required. 

 

	 	(C)	Any requirements of the New York City Department of Buildings, Fire Department or any other governing agency. Flexible sprinkler lines are not acceptable. 

 

	 	(D)	The Base Building sprinkler riser diagram updated to include the current installation(s). 

G. Fire and Life Safety System Engineering Drawings and Specifications: Must include at a minimum, but not be limited to the
following: 
  

	 	(A)	Plans showing a complete addressable fire/smoke detection devices, alarm devices, warden stations and other requirements of all applicable codes. The Consulting Engineer shall consult with the Landlord’s
Building Class “E” system vendor, and incorporate the actual point-to-point wiring diagrams for the required system modifications on the fire/life safety system drawings. These drawings must show a device location, an operational sequence,
and a one-line riser diagram. They must also include notes indicating the following: 

  

	 	(1)	Requirement for Contractor to retain Landlord’s Building Class “E” system vendor to install all fire alarm related devices and wiring “TURN KEY” inclusive of required filings, inspections and
permit fees. 

  

	 	(2)	That all required Class “E” System work must be included under the general contract as a sub-subcontract to the electrical sub-contractor; 

 

	 	(3)	 That the contractor has included in his price: all necessary re-programming, any head-end Class “E” System work; update of the Class “E” System (i.e. 

  
 B-7 

	 	
addressable devices), riser diagram, and any lateral wiring changes from the riser to the Fire Command Station and from the subject spaces to the applicable Class “E” System sub-panels. The modified diagram shall also note all types and quantities of field devices installed, relocated or modified in the Premises. 

 

	 	(4)	Except with respect to Landlord’s Work, Tenant is responsible for ensuring at its expense, that the Class “E” System sub-subcontractor and their sub-contractors
will correct any defect which may appear on any Fire Department inspection of the work covered under this contract and will be responsible for any fines levied and re-inspection fees as a result of any such letter of defect or violation. The Tenant
will provide the Building Manager the Fire Department Letter of Approval once obtained. 

  

	 	(5)	That the system modifications must be demonstrated as operable in the presence of the Consulting Engineer, the Building’s Chief Engineer, the Building Manager and/or his designee. Notice of the test must be given
to all parties at least 72 hours in advance; all tests are to be performed after normal business hours in order not to disturb other tenants of the building. 

  

	 	(6)	Upon entering into “Turn Key” agreement with the Fire Alarm vendor an additional contract for the term of the Tenants Lease must be signed between the Tenant and Fire Alarm vendor to maintain the Fire Alarm
devices in the demising space. Failure of Tenant to enter into agreement with the Fire Alarm vendor shall authorize Landlord to engage Fire Alarm vendor in performing all necessary maintenance work at Tenant sole expense and also places tenant in
default of Lease. 

 H. Structural Engineering Drawings and Specifications: Must include at a minimum, but not be
limited to the following: (No such modifications may be undertaken without the express written consent of Landlord’s structural engineer) 
  

	 	(A)	Plans & Details showing structural modifications or improvements required where deign loads exceed the structural floor load as noted in the Certificate of Occupancy (100lbs/SF Live Load), or where floor
openings or structural supports are required. Drawings must be developed by a structural engineer licensed to practice in the State of New York and must include, without limitation: 

 

	 	(1)	Structural steel modifications, fireproofing repairs, new slabs, including re-enforcing details, a list of all controlled inspections, and any other details necessary to fully
outline the work necessary to maintain the structural integrity; 

  

	 	(2)	All structural engineering calculations. 

 I. Card Access/Security Cameras Drawings and
Specifications: Must include at a minimum, but not be limited to the following: 
  

	 	(A)	Plans indicating additional Devices and or modifications. 

  
 B-8 

	 	(B)	Single-line diagram from to point to point of connections to. Tenant shall be responsible to comply with all codes when installing card access within their premises. Security cameras are not permitted within the
public corridor at any time. 

  

	 	(C)	Tenant shall be responsible for the operational and maintenance expense of all additional devices that they have installed. 

3. Permits: No work shall commence without providing Building Manager all original permits and approvals as required by any agencies having
jurisdiction. Tenant shall post a duplicate permit on the Premises in a conspicuous location, prior to the commencement of any work. 
  

	 	(A)	Tenant is required to utilize Landlord’s Building Filing Agent/Expediter for all DOB Applications, filings, close-outs and all agency work. 

 

	 	(B)	Self-Certification: Tenant shall submit all properly executed Alteration Type II forms or Alteration Type I forms, Department of Buildings Form PW1 and Department of Buildings Technical Report Forms for legal
application for permits and sign-offs as required by the scope of the work to be performed 

  

	 	(C)	If Tenant’s contractor intends to use the Self-Certification provision under the Department of Buildings Directive #14, all required Department of Buildings Technical Report Forms must accompany the alteration
request letter along with all other forms required. 

  

	 	(D)	At the completion of the job, all required signed and sealed Department of Buildings Technical Report Forms, a final letter of satisfactory completion from the Department of Buildings and a letter of approval from the
Fire Department (if required) must be given to the Building Manager. 

 4. Contractor Qualifications: Tenant shall submit to the
Building Manager in writing a list of all proposed General Contractors and sub-contractors that are to bid for any type of Tenant Alteration Work. Landlord in writing must then approve General Contractors and all sub-contractors in advance, as
provided in the Lease. Landlord reserves the right to stop any work being performed by the Tenants General Contractor and or sub-contractors who do not have written consent from the Building Management. Tenant may not employ any contractor or
subcontractor whose presence in the Building would cause labor disputes, work stoppages or picketing by other tradesmen working in the Building. 

  
 B-9 

 5. Insurance and Indemnification: Before commencing work, each contractor and subcontractor must
furnish certificates of insurance as required hereunder, including without limitation, certificates evidencing Builder’s Risk Insurance and Worker’s Compensation Insurance. Such Certificates of Insurance must be issued by an insurance
carrier authorized to do business in New York State and acceptable to the Landlord naming RFL 160 Fifth LLC, 200 Greenwich Fee LLC, RFR Holdings LLC, RFR Realty LLC, Owner’s Managing Agent, Owner’s Lender and Development Manager and their
respective partners, Directors, Officers, Employees, Agents and representatives. The Union Labor Life Insurance Company, as agent for the Lenders, their successors and assigns, Aby Rosen and Michael Fuchs (Principals), as agents for the Owner, shall
be Additional Insureds with the following coverage which must be maintained until completion of the work and written on an “occurrence” basis: 

For all contractors and subcontractors (except Minor Subcontractors (as hereinafter defined)): 

(I) Worker’s Compensation and Employers’ Liability Insurance covering each and every worker employed in, about or upon the work, as
provided for in all statutes applicable to Worker’s Compensation and Employers’ Liability; 
 (II) Commercial General Liability
Insurance for not less than the following limits: 
  

	 	(A)	Personal Injury: $5,000,000 per person 

 $5,000,000 per occurrence 

 

	 	(B)	Property Damage: $500,000 per occurrence 

 $5,000,000 per aggregate 

 

	 	(C)	Tenant must also carry automobile liability insurance and blanket contractual liability coverage for Tenant’s indemnity obligations to Landlord under the Lease into which this “Construction
Guidelines” is incorporated; 

  

	 	(III)	Umbrella Coverage: $5,000,000 per occurrence; $5,000,000 per aggregate; and 

  

	 	(IV)	Before commencing work, such contractor/subcontractor must deliver to Landlord: 

 An agreement
satisfactory to Landlord pursuant to which contractor/subcontractor agrees to indemnify and hold harmless the Landlord against loss or expense by reason of liability imposed by law upon Landlord because of personal injuries (including death),
accidentally sustained by any person or persons or on account of damage to property arising out of or in consequence of the performance of any Alterations caused by the negligence of contractor/subcontractor, its employees, agents,
(sub-)subcontractors or suppliers. 
 For minor subcontractors whose work engagements shall not (x) include work on any of the structural
elements of the Building or Building systems or (y) cost more than an aggregate amount (including labor and materials) of $75,000.00 (“Minor Subcontractors”): 

 
  

	 	(I)	Worker’s Compensation and Employers’ Liability Insurance covering each and every worker employed in, about or upon the work, as provided for in all statutes applicable to Worker’s Compensation and
Employers’ Liability; 

  

	 	(II)	Commercial General Liability Insurance for not less than the following limits: 

  

	 	(A)	Personal Injury: $2,000,000 per person 

 $2,000,000 per occurrence 

 

	 	(B)	Property Damage: $500,000 per occurrence 

 $2,000,000 per aggregate 

  
 B-10 

	 	(III)	Umbrella Coverage: $2,000,000 per occurrence; $2,000,000 per aggregate; and 

  

	 	(IV)	Before commencing work, such subcontractor must deliver to Landlord: 

 An
agreement satisfactory to Landlord pursuant to which subcontractor agrees to indemnify and hold harmless the Landlord against loss or expense by reason of liability imposed by law upon Landlord because of personal injuries (including death),
accidentally sustained by any person or persons or on account of damage to property arising out of or in consequence of the performance of any Alterations caused by the negligence of subcontractor, its employees, agents, sub-subcontractors or suppliers. 

  
 B-11 

 Tenant’s Responsibilities during Construction of Alterations 

1. Permissible Work Periods and Work in Non-Tenant Areas: The following work shall be performed after
6:00 p.m. and before 8:00 a.m. on Business Days or on Weekends, provided that at least 24 hours written notice is given to the Building Manager during the regular work week: Landlord’s representative at Tenant’s expense must supervise all
demolition related to structural and MEP components at Landlord’s discretion. 
  

	 	(A)	Work in any other tenant’s areas (written request to Building Management at least 5 business days notice); 

  

	 	(B)	Work in any common area of the Building that would interfere with the normal use of such common area; 

  

	 	(C)	Work requiring the shut down or cessation of any utility (At least 20 business days notice) 

  

	 	(D)	Any coring, drilling, hammer drilling, demolition or other activity that generates or causes noises that can be heard outside the Premises and that disrupts other occupants of the Building or interferes with the conduct
of their business, as reasonably determined by Landlord. Any costs associated with any utility shutdown will be at Tenant’s expense. 

  

	 	(E)	All work involving areas other than Tenant’s Premises must be completed by the next Business Day with such area restored to the same condition as existed immediately prior to such work. 

2. Protection of Building: All public areas must be protected to the sole satisfaction of the Landlord. Any damage to the Building (including
tenanted space) caused by Tenant or its contractors shall be repaired at Tenant’s and or contractors expense to the sole satisfaction of Landlord. Flooring, walls, and service elevator door/trim in common floor areas must be protected including
but not limited to the following at all times: 
  

	 	(A)	1/4” Masonite over the carpet and terrazzo from the area of work to freight service car, taped at seams and covering the entire carpet; 

 

	 	(B)	1/4” Masonite over freight entrance doors; 

  

	 	(C)	A clean, damp walk-off carpet from the work area, which must be changed by contractor upon demand by the Building Manager. 

3. Demolition and Construction: Except as otherwise provided in the Building Rules and Building Standards for Alterations, Tenant shall be
permitted to perform Alterations during Operating Hours, provided that such work does not unreasonably interfere with or interrupt the operation and maintenance of the Building or unreasonably interfere with or interrupt the use and

  
 B-12 

 
occupancy of the Building by other tenants in the Building. Otherwise, Alterations shall be performed at Tenant’s expense and at such times as Landlord may from time to time reasonably
designate. All demolition and removals must be performed after 6 p.m. and before 8:00 a.m. on Business Days or on weekends and the Building Manager must be given at least 48 hours prior written notice. If the demolition involves a Department of
Buildings’ permit, an after-hours permit is required. The delivery, handling, and installation of materials, equipment, and debris must be prearranged. Cleaning must be controlled to prevent dirt and dust
from infiltrating into adjacent tenant premises or mechanical areas. Landlord’s representative at Tenant’s expense must supervise all demolition and installation of materials and or equipment, which impact the floor above, below, or
adjacent tenant space. 
 4. Controlled Inspections: Tenant at their sole expense shall perform controlled inspections conducted by a third
party testing agency approved by Landlord for any Work involving structural modifications, welding, fire-stopping, fireproofing, etc., and any Work affecting the Building systems, including without limitation, the Class “E” System. 

5. Landlord’s Review of Work: All work shall be subject to periodic review by Landlord’s representative. Such reviews shall be done at
Tenant’s expense (as provided in the Lease). 
 6. Inquiries and Submissions: Contact Building Manager with all inquiries, submissions,
approvals, and all other matters. 
 7. Storage of Materials and Tools: Must be contained within the Tenant’s Premises no exceptions. All
fire exists must be kept clear and accessible at all times. 
 8. Building Construction Services: Tenant and their contractors must comply
with the Building’s rules concerning the availability and charges for use of a Landlord designated elevator, personnel, sprinkler and fire alarm drain downs and disconnects, controlled inspections, drawing reviews and the handling of materials,
equipment and debris. 
  

	 	(1)	Arrangements for Landlord designated elevator use must be made in advance as required by the Lease. Tenant is responsible for any and all charges that may arise from such request. Tenant will be charged for service if
the request for use is not cancelled within 8 business hours. Landlord shall have the right to stop construction services (Landlord designated elevator usage, engineering, security and porter services, etc.) if tenant or tenant’s
representative fail to pay invoices issued to them in accordance with the Lease within the allotted time therefor. All future construction service requests shall be payable via certified check the day of the requested service at the minimum rate set
by the management office. 

  

	 	(2)	Tenant’s vendor(s), contractor(s) and sub-contractor(s) shall utilize only the Landlord designated elevator. Anyone violating this rule will be escorted from the building immediately. All vendor(s)’,
contractor(s)’ and sub-contractor(s)’ personnel are to use the Landlord designated elevator only at all times during the duration of the work. 

  
 B-13 

 9. Prohibited Activities: Burning of holes in structural steel and chopping of fireproofing around
the structural steel is prohibited unless specifically noted in the Tenant’s drawings, reviewed, and approved by the Landlord. 
 10. Completion
Certificates & Completion of Work: Tenant and/or Tenant’s contractor shall submit the following certificates to Landlord upon completion of work, including, but not limited to: 

 

	 	(1)	Alteration Type II Application approvals and sign-offs issued by the Department of Buildings (including fireproof wood test reports) 

 

	 	(2)	Equipment Use Permits 

  

	 	(3)	Approvals of the Landmarks Preservation Commission of New York City (if Applicable) 

  

	 	(4)	Electrical and air-conditioning certificates issued by the Bureau of Gas and Electricity, the Board of Fire Underwriters, and any other agency having jurisdiction

  

	 	(5)	An air balance report performed and signed by building’s designated air balancer 

  

	 	(6)	Final “As built” Drawings in AutoCAD and mylar sepias showing all work in full detail. 

 11.
As-Built Drawings and Specifications: Upon completion of the work, Tenant shall provide the Building Manager with 3 sets of contractor’s drawings and an electronic copy of all drawings on AutoCAD labeled as “As-Built
Drawings” indicating any changes to existing architectural, structural, electrical, mechanical, fire alarm, plumbing or telephone wiring. 
 12.
Update of Building’s Drawings: Landlord, at Tenant’s expense, shall make whatever updates are necessary to the Building’s drawings to reflect the Alterations. This includes, but is not limited to updating electrical, fire
alarm and tenant condenser riser diagrams to the extent these systems are affected by the tenant’s work. 
 13. Contractor’s Rules and
Regulations: Tenant shall have there General Contractor/contractors comply with the attached Contractor’s Rules and Regulations. 

  
 B-14 

 160 FIFTH AVENUE 

CONTRACTOR’S RULES AND REGULATIONS 

The following rules and regulations will dictate the conduct of all contractors performing construction related services at 160 fifth Avenue. These
regulations are presented as a guide as to the manner in which contractors, (which refers to the employees of the general and all sub contractors), are expected to conduct their daily functions, but are not the limit of regulations that may be
enforced during the scope of the project. 
 Landlord reserves the right to amend as appropriate these rules and regulations as the particular situation
dictates. The overall intent of these regulations is to ensure the efficient completion of the tenants’ project with minimal inconvenience to the other tenants on the construction floor and throughout the building. The management will determine
the meaning of these rules and regulations should uncertainty regarding the meaning of any particular statement arise. 
  

	 	(i)	Prior to the commencement of any work within the building the General Contractor shall provide to Management a Certificate of Insurance and required Endorsement for General Liability and Workmen’s Compensation in
the amounts, form and worded exactly in the manner of the example attached plus the same for each of their sub-contractors. 

  

	 	(ii)	Except as otherwise provided in the Lease, all deliveries of materials shall be made before 8:00 AM or after 6:00 PM, Monday - Friday. No large deliveries shall be allowed during regular business hours. Arrangements for
freight elevator access must be made with the management office by no later than 4:00 PM on the day prior to the scheduled delivery. Arrangements for Saturday deliveries must be made no later than 1:00 PM on the Friday prior. The contractor is
responsible for protecting the elevators, corridors (carpets and walls) to the satisfaction of the management. The areas will be inspected prior to and immediately after the deliveries by both a representative of the contractor and building
management, the contractor and /or tenant will be held liable for any and all damages incurred during the course of the project 

  

	 	(iii)	Except as otherwise provided in the Lease, all construction and /or demolition debris must be removed from the premises before 7:00 am, rubbish containers must not be left unsupervised while waiting for pickup,
contractor will have a laborer on site to ensure that the containers are properly removed and any residual debris cleaned up immediately. No containers will be permitted to remain outside the building after 8:00 am, if the rubbish
contractor fails to remove the material by the appointed time, the contractor must bring the containers back onto the project site. 

  
 B-1 

	 	(iv)	There will be a designated elevator for use as freight and will be operated only by building personnel, under no circumstances is the contractor permitted to take control of the elevator for any reason.
Building trades are not permitted on the passenger elevators and stairwells; all trades will enter and exit the work areas via the designated freight elevator. Construction personnel found violating these polices will be escorted from
the building permanently. All construction work scheduled for after normal business hours must reserve the freight elevator for transportation to and from the work site at all times. 

 

	 	(v)	Contractors are expressly prohibited from using the restroom facilities on occupied floors, should the need arise, contractors shall use the facilities in the lower basement areas or as otherwise directed
by the Landlord. If there are no other occupants on the floor on which the project is being conducted, the contractor is responsible to clean and maintain the restrooms used on a daily basis by its personnel. The construction areas
must be kept clean and swept at the end of each work day, using an approved dustless sweeping compound, damp mats must be placed at all points of egress from the construction site to prevent / limit the carryover of dust and dirt through the other
areas of the building. Failure to properly protect or prevent the transmission of dirt to other areas of the building / floor will result in the contractor being held liable for the costs to clean and if deemed necessary replacement of the damaged
areas. 

  

	 	(vi)	There will be no use of obscene or potentially offensive language, yelling, comments, and gestures in any location within the building. Graffiti of any kind will not be tolerated anywhere
within the building. Radio playing is not permitted. Individuals violating these rules will be escorted out of the Building. 

  

	 	(vii)	Contractors shall not, in any way, interfere or cause interruptions in the daily operation and maintenance of the building or the use of the building facilities by the tenants. 

 

	 	(viii)	All work being conducted on an after hours basis will be supervised by the building engineers and/or security staff; all costs associated with this overtime supervision shall be the responsibility of the tenant and/or
contractor. 

  

	 	(ix)	Core drilling of floors, heavy banging, chopping and the use of power assisted tools for hammering must be started after 6:00 pm and completed prior to 8:00 am. Contractors are expected to supervise their
employees and to ensure that the work is completed in an efficient professional manner at all times without any unnecessary noise. Noise complaints from surrounding tenants will cause postponement of the offending work until non business hours.

  
 B-2 

	 	(x)	The building management office must be notified prior to the commencement of any welding, sweating, soldering or cutting of wood or other materials which might cause smoke to be generated, so that arrangements may be
made to prevent the transmission of false fire alarms throughout the building or to the NYC Fire Department via the buildings Class “E” system. Any alarm transmitted due to the negligence of the General Contractor or any of their
sub-contractors, tenant’s and or building’s contractors and or vendors shall be levied a $1,000.00 penalty for each Alarm Occurrence and or that penalty will be deducted from the next invoice statement. There are NO EXCEPTIONS. Failure to
pay such penalty shall result in the contractors or vendors removal from the building. City Permits, fire watch (by persons carrying Form 820-Certificate of Qualification and Fitness) and protective blankets are required for all burning and
welding. It is the Tenant’s General Contractor’s responsibility to provide for the proper fire watch personnel as per code, and all fire watch personnel must sign-in and out with the Building’s Fire safety director on duty. A log will
be maintained at the lobby desk for this purpose. 

  

	 	(xi)	The building management office must be notified prior to any work being done on the sprinkler system. The building engineers are the only persons permitted to shut down and drain the sprinkler loops and /
or riser to a particular floor to allow alterations to the system. No work of any kind related to the sprinkler system may be started until the contractors confirms with the building engineer and security that the fire alarm system has been placed
on standby, the central station has been notified and the system properly drained and all valves secured. Sprinkler systems must be filled and returned to full operation at the end of each working day, if for some reason the restoration of sprinkler
service to the floor is not possible, the contractor is responsible for establishing and maintaining a certified fire guard on site until such time as the system is restored and operational. If the contractor is unable to provide such a fire guard,
the building will provide same at additional cost to the tenant and / or contractor. Any alarm transmitted due to the negligence of the General Contractor or any of their sub-contractors, tenant’s and or vendors shall be levied a
$1,000.00 penalty for each Alarm Occurrence. There are NO EXCEPTIONS. Failure to pay such penalty shall result in the contractors or vendors removal from the building. 

 

	 	(xii)	Access to all building mechanical areas (i.e. telephone, electric, and HVAC rooms) will be provided only by the building engineers and or security, at the end of each work day the contractor must ensure that these areas
are secured. It is strictly prohibited for anyone to block open any door to equipment rooms or prevent them from returning to their normally locked position by any means. 

  
 B-3 

	 	(xiii)	Contractor and Sub Contractors shall not enter any other areas of the building and specifically other tenant areas without escort by: (a) building engineer, or (b) building security officer. Contractors
may only use the staircases in the event of an emergency only. 

  

	 	(xiv)	The lobby security station is not to be used as a place to conduct contractors business (i.e. Filling out paperwork, receiving materials etc.); no telephone calls may be made at the lobby, it is expected that each
contractor will provide a means for their own communication. The building staff is not authorized to accept or receive any packages or materials for the contractor. 

 

	 	(xv)	All construction work scheduled for after normal business hours must reserve the designated freight elevator for transportation to and from the work site at all times. 

 

	 	(xvi)	There is absolutely NO SMOKING ALLOWED within the premises. 

  

	 	(xvii)	Fire Extinguishers fully charged and in sufficient quantity and type per NYFD regulations must be on the job-site at all times. 

  

	 	(xviii)	The General Contractor will be required to provide an acceptable Site Safety Plan for approval by Building Management prior to the start of work. This plan shall include but not be limited to: 

 

	 	(a)	Designation of site safety person as a primary point of contact for safety related issues. This individual will be responsible for enforcement of all safe work rules identified here-in and applicable to the work area.
Provide a 24 hour telephone number for this person. 

  

	 	(b)	Designation of all sub-contractor safety representatives as a primary point of contact for each sub-contractor. Provide 24 hour phone number for each person. 

 

	 	(c)	Sign-in sheet indicating the reading and understanding of the provisions within the safety plan by all workers under the jurisdiction of the General Contractor. All workers must read and sign the site safety plan.

  

	 	(d)	Floor Plan indicating primary means of egress. 

  

	 	(e)	Location and type of fire extinguishers. 

  

	 	(f)	Hot Work Program to be exercised when burning or welding. Including certificates of Fitness for all personnel who will be responsible for the fire watch and use of all acetylene cutting and welding apparatus.

  
 B-4 

	 	(g)	Lock-out/tag-out Program for Energized devices, circuits, and control of Hazardous Energy per current OSHA regulations to be exercised during applicable work. 

 

	 	(h)	Identity of person(s) responsible for maintenance of fire alarm devices, including daily responsibility of covering and un-covering of all active smoke detectors. Provide a 24 hour telephone number for this person.

  

	 	(i)	Weekly Safety Meetings. 

  

	 	(xix)	Properly protect all openings, including but not limited to elevator openings, induction units, etc., to protect against dirt and dust from permeating into them or to other floors during the performance of the work.

  

	 	(xx)	General Contractor shall clean and or repair all public areas daily, and or other Tenant Premises as may be required due to the results of the Contractor’s work. 

 

	 	(xxi)	Any mechanic’s liens filed against the demised premises of the building shall be discharged by Tenant or Tenant’s general Contractor at their own expense within thirty (30) days after such filing, by
payment or by filing of the bond required by law or otherwise. Proof of such discharge shall be forwarded to the Building Management immediately thereafter. 

These rules are established to familiarize the contractor with what is expected of them and what will or will not be permitted during the completion of the
project and may be changed at the discretion of the building management as dictated by the circumstances; your compliance with these rules is required. 

If you have any questions regarding these rules and regulations, please contact the building Management Office
@                    . 

  
 B-5 

 Forms 

PARTIAL RELEASE AND WAIVER OF LIENS 
  

			
	The undersigned,	 	  

					
	(“Releasing Party”), located at	 	  
	 	,

 having performed or furnished, or having caused to be performed or furnished, labor, services, or materials in the
construction, alteration, or improvement of that property of the Owner described as: 
  

 
  

 
  

 
  

 
 (the “Project”, which term
includes the real property on which construction is taking place) certifies that the Releasing Party has been paid a partial payment in the amount of $             for
                     pursuant to a contract with
                     (Partial Payment) in the total amount of $            
(including all change orders approved to date), and that the total amount Releasing Party has received to date, NOT including the partial payment referred to above, is $            .

 To the extent of the Partial Payment, the Releasing Party does hereby remise, release, and forever discharge, for itself and its successors,
(tenant name and or RFL 160 Fifth LLC) and its successors, heirs, executors, and administrators of and from all manner of action and actions, cause and causes of actions, suits, debts, dues, sums of money, accounts, reckonings, bonds,
bills, specialties, covenants, contracts, controversies, agreements, promises, variances, trespasses, damages, judgments, extents, executions, claims, and demands whatsoever in law, in admiralty, or in equity which against the said
             the Releasing Party ever had, now has, or which it or its successors hereafter can, shall, or may have in connection with any and all claims of any nature whatsoever
arising out of or relating to the Project. 
 Further, to the extent of the Partial Payment, the Releasing Party certifies, under oath and in accordance
with all applicable statutes, laws, and regulations, that all lienors, including laborers, subcontractors, or material men, have been paid in full for all materials, equipment, fees, licenses, insurances, and taxes of every description and that
there are no liens, causes for liens, or claims against the Releasing Party for such items. The Releasing Party certifies that he will indemnify and save harmless the Owner and Construction Manager from any and all manner of claims, liens, suits,
losses, costs, expenses, and damages, including but not limited to reasonable attorney’s fees arising out of or resulting from the contract agreement referred to above or any work performed or material supplied thereunder and hereby releases
forever all claim, title, and interest in the Project for the same through the effective date of this Release. 

  
 B-6 

 Further, to the extent of the Partial Payment, the Releasing Party for value received does hereby release and
discharge the Project from any and all liens and claims of liens, equitable or legal, which the undersigned has or may have against the Project for labor, services, or materials to the effective date hereof and further hereby releases and discharges
any and all claims against the Payment Bond, if any, applicable to the Project for labor, services, or materials to the effective date hereof. Lien rights or rights against any Payment Bond which the Releasing Party may acquire for labor, services,
or materials furnished subsequent to the effective date hereof are not released. 
 Further, the Releasing Party warrants that no assignment of claims for
payments, rights to perfect a lien against the Project, or claims against the Payment Bond have been made and that the undersigned has the authority to execute this Partial Release and Waiver of Liens and has performed the labor and services and
supplied the materials required of the Releasing Party to the state of completion of said improvements for which payment is being applied. The undersigned has personal knowledge that the statements made herein are true and correct. 

Effective date:             , 20    . 

 

					
	[                    ]
		
	By:	 	  

		 	Name:	 	  

		 	Title:	 	  

  

			
	STATE OF	 	  

		
	COUNTY OF	 	  

 The foregoing instrument was acknowledged before me this      day of
            , 20    , by                     , a
                     on behalf of said             . He/She is personally
known to me or has produced                      as identification and did (did not) take an oath. 

 

			
	My commission expires:	 	  

		
	Signature:	 	  

		
	Name:	 	  

	Legibly printed

 (AFFIX OFFICIAL SEAL) Notary Public, State of
                     

  
 B-7 

 FINAL RELEASE AND WAIVER OF LIENS 

 

			
	The undersigned,	 	  

					
	(“Releasing Party”), located at	 	  
	 	,

 having performed or furnished, or having caused to be performed or furnished, labor, services, or materials in the
construction, alteration, or improvement of that property of the Owner described as: 
  

 
  

 
  

 
  

 
 (the “Project”, which term
includes the real property on which construction is taking place) acknowledges receipt of final payment in the amount of $             for
                     pursuant to a contract with
                     in the total amount of $             (including all
change orders approved to date), and that the total amount Releasing Party has received to date NOT including the final payment referred to above is $            . 

The Releasing Party does hereby remise, release, and forever discharge, for itself and its successors, (tenant name and or RFL 160 Fifth LLC)
and its successors, heirs, executors, and administrators of and from all manner of action and actions, cause and causes of actions, suits, debts, dues, sums of money, accounts, reckonings, bonds, bills, specialties, covenants, contracts,
controversies, agreements, promises, variances, trespasses, damages, judgments, extents, executions, claims, and demands whatsoever in law, in admiralty, or in equity which against the said
             the Releasing Party ever had, now has, or which it or its successors hereafter can, shall, or may have in connection with any and all claims of any nature whatsoever
arising out of or relating to the Project. 
 Further, the Releasing Party certifies, under oath and in accordance with all applicable statutes, laws, and
regulations, that all lienors, including laborers, subcontractors, or material men, have been paid in full for all materials, equipment, fees, licenses, insurances, and taxes of every description and that there are no liens, causes for liens, or
claims against the Releasing Party for such items. The Releasing Party certifies that he will indemnify and save harmless the Owner and Construction Manager from any and all manner of claims, liens, suits, losses, costs, expenses, and damages,
including but not limited to reasonable attorney’s fees arising out of or resulting from the contract agreement referred to above or any work performed or material supplied thereunder and hereby releases forever all claim, title, and interest
in the Project for the same. 
 Further the Releasing Party for value received does hereby release and discharge the Project from any and all liens and
claims of liens, equitable or legal, which the undersigned has or may have against the Project for labor, services, or materials and further hereby releases and discharges any and all claims against the Payment Bond, if any, applicable to the
Project for labor, services, or materials to the effective date hereof. 

  
 B-8 

 Further, the Releasing Party warrants that no assignment of claims for payments, rights to perfect a lien against
the Project, or claims against the Payment Bond, if any, have been made and that the undersigned has the authority to execute this Final Release and Waiver of Liens and has performed the labor and services and supplied the materials required of the
Releasing Party. The undersigned has personal knowledge that the statements made herein are true and correct. 
 Effective date:
            , 20    . 
  

					
	[                    ]
		
	 By:
	 	  

		 	Name:	 	  

		 	Title:	 	  

  

			
	STATE OF	 	  

		
	COUNTY OF	 	  

 The foregoing instrument was acknowledged before me this      day of
            , 20    , by                     , a
                     on behalf of said             . He/She is personally
known to me or has produced                      as identification and did (did not) take an oath. 

 

			
	My commission expires:	 	  

		
	Signature:	 	  

		
	Name:	 	  

	Legibly printed

 (AFFIX OFFICIAL SEAL) Notary Public, State of
                     

  
 B-9 

 SCHEDULE C 

WORK AGREEMENT 
 Landlord
and Tenant hereby covenant and agree as follows: 
 ARTICLE I 

LANDLORD’S WORK 

Except as otherwise specifically provided, Landlord, at its expense, shall furnish, install and perform in the Premises, using Building
Standard materials and quantities, all of the work (“Landlord’s Work”) shown on the working drawings (the “Plans”) hereafter to be prepared by Tenant (with the cooperation of Tenant’s architect) and
approved by Landlord, which approval shall not be unreasonably withheld or delayed if the Plans are consistent with the work shown on the layout plan annexed to this Work Agreement as Exhibit C-1. Tenant shall submit the Plans to
Landlord on or before April 16, 2010, time being of the essence. If Landlord shall object to any part of the Plans, such objections shall be made in a writing given by Landlord to Tenant within five (5) Business Days after Landlord’s
receipt of the Plans, which objections shall be set forth in such notice in sufficient detail to enable Tenant to modify such Plans in order to make them acceptable to Landlord. Tenant shall cause the Plan to be modified within three
(3) Business Days after Landlord shall have given its comments to Tenant. Landlord shall respond to such revised plans within three (3) Business Days after Landlord’s receipt thereof. Notwithstanding anything contained herein to the
contrary, Landlord’s costs and expenses incurred with respect to Landlord’s Work, Additional Work (as hereinafter defined) and the cost of permits, filing fees and Landlord’s expediter, shall not exceed the amount of the Tenant
Improvement Allowance defined in this Lease (“Landlord’s Maximum Work Cost”); provided, however, Landlord’s Maximum Work Cost will not include Landlord’s costs with respect to the review, comments to and
approval of the Plans. Tenant shall pay all costs and expenses in excess of Landlord’s Maximum Work Cost upon demand and as otherwise directed by Landlord. Landlord’s bidding, pricing and change orders shall be on an open-book basis. 

Landlord and Tenant agree that Landlord shall bid out Landlord’s Work to at least the following General Contractors: TriStar, James E.
Fitzgerald, StructureTone, Lewis & Kennedy and ACC Construction, and each such General Contractor will bid all major trades to at least three (3) subcontractors who are pre-qualified to perform work in the Building and who have been
provided with a copy of the project schedule. The General Contractors shall provide their fee (as a percentage of the work), general conditions and general requirements separately, with the balance of the subcontractor work provided as a lump sum.
After the bids are received, Landlord shall recommend the selection of a General Contractor, subject to Tenant’s approval (which shall not be unreasonably withheld). (Tenant shall approve or reject such recommendation within two
(2) Business Days, and if Tenant shall fail to respond within such period of time, Tenant shall be deemed to have approved Landlord’s recommendation.) After a General Contractor has been selected, such General Contractor shall provide the
subcontractors’ bids, including line item scopes, for Tenant’s review. 

  
 C-1 

 Tenant shall respond to Landlord’s submission of any change orders within two
(2) Business Days. In the event that Tenant shall fail to so respond, any change in Landlord’s Work or the Additional Work requested by Tenant shall be deemed to have been disapproved and withdrawn by Tenant, and any change in
Landlord’s Work or the Additional Work requested by Landlord shall be deemed to have been approved by Tenant. Notwithstanding the foregoing, any changes as may be required by any Government Authority or department thereof affecting the
construction of the Building and/or the Premises or any Landlord’s Work or any Additional Work to be performed therein may be complied with by Landlord in completing the same and shall not be deemed a violation of the Plans or any provision of
this Schedule C and shall be accepted and approved by Tenant. 
 ARTICLE II 

ADDITIONAL WORK 
 If Tenant
shall request Landlord to perform additional work in the Premises or to substitute for any Building Standard item or quantity of work forming part of Landlord’s Work, which causes Landlord’s Work to exceed Landlord’s Maximum Work
Cost, such request shall be deemed to be Additional Work (hereinafter “Additional Work”) and Tenant shall pay to Landlord the actual cost of labor and materials for the Additional Work plus a fee payable to Landlord’s
designated construction manager or the Manager of ten (10%) percent for overhead and ten (10%) for profit, and paid by Tenant as set forth below. Landlord shall estimate reasonably the cost of the Additional Work depicted on the Plans or
requested by Tenant and advise Tenant of such estimate (the “Plan Based Estimate”) and Tenant shall either promptly withdraw its request for all or part of the Additional Work so estimated or pay to Landlord, prior to the
commencement of Landlord’s Work or the Additional Work, the amount by which the Plan Based Estimate exceeds the Preliminary Estimate, if any, which payment shall be reconciled by Landlord and Tenant upon the completion of the Additional Work.

 If in Landlord’s commercially reasonable judgment, any items of Landlord’s Work or Additional Work shall involve ordering of
materials or products which must be specially fabricated to order and thus will prevent Landlord’s substantial completion of Landlord’s Work beyond 60 days after the commencement of Landlord’s Work, then Landlord may require Tenant to
agree on a fixed Commencement Date of this Lease (allowing a reasonable time for the performance of Landlord’s Work in absence of the necessity of performing Landlord’s Work or the Additional Work occasioning such material delay). If the
parties cannot agree upon a fixed Commencement Date, then Landlord shall have the right to decline to perform such portion of Landlord’s Work or such Additional Work, and Tenant shall be responsible for the performance thereof (subject to the
terms of this Lease) after the completion of the remainder of Landlord’s Work and any other (non-objected to by Landlord) Additional Work. 

  
 C-2 

 ARTICLE III  

TENANT’S AUTHORIZED AGENT(S) 

Tenant shall identify a duly authorized agent to provide design and construction-related instructions in writing, and such agent shall bind
and act for Tenant with respect to all matters relating to the build-out of the Premises. 
 ARTICLE IV  

TENANT’S OFFICE INSTALLATIONS 

In the event Tenant shall desire to make any installations of its furniture, fixtures and office equipment (herein called
“Tenant’s Office Installations”) which are not to be made by Landlord for Tenant, the following shall apply: 
 On
condition that such Tenant’s Office Installations will not require any structural change, and further provided that all Landlord’s Work and Additional Work required to be made by Landlord therein shall have reached a point with respect to
which, in Landlord’s sole judgment, exercised in good faith, the making of Tenant’s Office Installations will not delay or hamper Landlord in the completion of Landlord’s Work or any Additional Work, Tenant may enter the Premises for
the purpose of making Tenant’s Office Installations, approximately two weeks prior to the Commencement Date after notice of the same by Landlord, subject, however, to the applicable provisions of Article 6 of the Lease. The
foregoing shall include access by Tenant’s telephone, cable and other information technology contractors. 
 Prior to the Commencement
Date, any entry by Tenant in or on the Premises shall be at Tenant’s sole risk and shall be pursuant to all of the terms and conditions of the Lease, except for the payment of Rental. Tenant’s Office Installations shall be completed free
of all liens and encumbrances. 
 In the event Tenant or any agent or contractor of Tenant shall enter upon the Premises or any other part
of the Building, Tenant agrees to indemnify and save Landlord free and harmless from and against any and all claims whatsoever arising out of said entry or any work performed by such contractor. Tenant’s agents, contractors and their employees
shall comply with the special rules, regulations and requirements of Building management for the performance of work and coordination of said agents, contractors and their employees so as to avoid interference with the operation of the Building
and/or the business operation of other tenants. 
 ARTICLE IV 

TENANT’S DELAY 
 If
there shall be a delay in the occurrence of the Commencement Date due to any of the following: (i) in the Substantial Completion of Landlord’s Work, or any portion thereof, due to any act or omission of Tenant, its contractors,
subcontractors, architects, space designers, agents or employees, including, without limitation, delays in submission of information; (ii) delays in payment of any costs and expenses in excess of Landlord’s Maximum Work as set forth in
this Work Agreement for more than ten (10) Business 

  
 C-3 

 
Days after demand therefor; (iii) delays beyond the specified dates or allotted time periods in submission of the Plans or any revised plans to Landlord or giving authorizations or approvals
in accordance with the time periods set forth above or delays resulting from the fact that, under good construction practice, portions of Landlord’s Work must be scheduled after the completion of certain items of Tenant’s Office
Installations; (iv) resulting from Tenant’s request for Landlord to utilize non-Building Standard materials or products in Landlord’s Work, or to perform Additional Work; or (v) any event defined in Article 1 of the body
of this Lease as a Tenant Delay (any of the foregoing being called a “Tenant’s Delay”) then the Premises shall be deemed Substantially Completed on the date the Premises would have been available but for the duration of any
Tenant Delay, even though work to be done by Landlord has not been commenced or completed. 
 The parties recognize that a Tenant’s
Delay may be aggravated or extended by a strike, labor problem, materials or labor shortage, or loss of time due to construction scheduling changes occasioned by such Tenant’s Delay or other Unavoidable Delays, any or all of which would not
have adversely affected the timely completion of Landlord’s Work in the absence of such Tenant’s Delay and agree that the duration of Tenant’s Delay should include all delays resulting from such other causes, notwithstanding that as a
result thereof, the Tenant’s Delay in question may substantially exceed, in duration, the length of time during which the act or omission of Tenant or Persons Within Tenant’s Control causing such Tenant’s Delay may have occurred or
continued. 

  
 C-4 

 EXHIBIT C-1 

LAYOUT PLAN 
 (attached)

  
 Exhibit C-1 

  
 

 

  
 Exhibit C-2 

 SCHEDULE D 

CLEANING SERVICES 
  

	A.	The following general cleaning will be performed nightly, Monday through Friday, excluding union and legal holidays: 

  

	 	1.	All carpeting will be vacuumed once per week and carpets will be swept as needed, the remaining four (4) nights. 

  

	 	2.	All composition floor tiling will be swept and dust-mopped with a chemically-treated mop (for dust control) one (1) time per week. 

 

	 	3.	All desks will be dusted. Tenant personalty and work product will not be moved. 

  

	 	4.	Wastepaper baskets will be empties and trash removed to a designated location in the Premises. Plastic liners will be installed weekly in all trash receptacles at Tenant’s expense. 

 

	 	5.	Wipe clean of all water fountains and coolers and empty of waste water 

  

	B.	The following lavatory service will be performed Monday through Friday, excluding union and legal holidays: 

  

	 	1.	Porcelain fixtures will be scoured clean. 

  

	 	2.	Both sides of toilet seats will be washed with a mild germicidal solution. 

  

	 	3.	Bright work will be dry polished. 

  

	 	4.	Trash receptacles will be emptied and cleaned, as needed. 

  

	 	5.	Mirrors will be wiped clean. 

  

	 	6.	Partitions will be wiped down, as necessary. 

  

	 	7.	Shelves and counters will be wiped clean. 

  

	 	8.	Floors will be mopped with a mild disinfectant. 

  

	 	9.	Lavatory supplies will be furnished and installed at the Tenant’s expense. 

  

	C.	The following shall be performed weekly: 

  

	 	1.	All chairs, tables, cabinets and attachments will be dusted weekly. Tenant personalty and work product will not be moved. 

  

	 	2.	Window sills will be dusted. Tenant personalty and work product will not be moved. 

  

	 	3.	Moldings and ledges within hand reach will be dusted. 

  
 D-1 

	D.	The following shall be performed quarterly: 

  

	 	1.	Dust in place all picture, frame, charts, graphs and similar wall-hangings not reached in nightly cleaning. 

  

	 	2.	Dust all vertical surfaces and walls, partition doors, door bucks and other surfaces not reached in nightly cleaning. Tenant personalty and work product will not be moved. 

 

	E.	Window Cleaning: 

  

	 	1.	All windows are to be cleaned inside and out two (2) times per year. 

  
 D-2 

 SCHEDULE E 

FORM OF LETTER OF CREDIT 

[ISSUER] 
 [Date] 

RFL 160 Fifth LLC 
 c/o RFR Realty LLC 

390 Park Avenue 
 New York, New York 10022 

Attention: President 
  

	 	Ref:	Irrevocable Letter of Credit No.              

Gentlemen: 
 By order of our client, [name of Tenant], [address
of Tenant], we hereby open in your favor our clean irrevocable Letter of Credit No.              for the aggregate sum of [amount of Security Deposit] United States Dollars, (U.S.
$        ) effective immediately and expiring at our [address of Bank] New York Office on
                     or any automatically extended date. 

Funds under this Letter of Credit are available to you against presentation of your sight draft(s) drawn on us marked “drawn under Irrevocable Letter of
Credit No.              date [date of Letter of Credit]”, and accompanied by the following: 

Beneficiary’s signed statement that [name of Tenant] has failed to comply with the terms and conditions of a contract described as Agreement of Lease
between RFL 160 Fifth LLC, Landlord, and [name of Tenant], Tenant, dated [date of Lease]. 
 It is a condition of this Letter of Credit that it shall be
deemed automatically extended without amendment for one year from the present or any future expiration date hereof, unless thirty (30) days prior to any such date we shall notify you by registered mail that we elect not to consider this Letter
of Credit renewed for any such additional period. Upon receipt by you of such notice, you may draw hereunder by means of your draft on us at sight, accompanied by the original Letter of Credit. 

This Letter of Credit is transferrable in whole but not in part by the beneficiary upon notice to the undersigned, without charge. Requests for transfer will
be in the form of Annex A attached hereto, duly completed by an officer of your company and accompanied by the original of this Letter of Credit. 
 If we
receive your sight draft as mentioned above, in accordance with the terms and conditions of this credit, here at our [address], New York Office we will promptly honor the same. 

  
 E-1 

 This Letter of Credit is subject to the Uniform Customs and Practice for Documentary Credits (1993 Revision)
International Chamber of Commerce Brochure No. 500, shall be deemed to be a contract made under, and as to matters not governed by the UCP, shall be governed by and construed in accordance with the laws of the State of New York and applicable U.S.
Federal Law. 
  

			
	[Name of Bank]
		
	By:	 	  

		 	Authorized Signature
		 	Title:

 [ANNEX A TO BE ADDED BY ISSUER, IF REQUIRED] 

  
 E-2 

 SCHEDULE F 

RULES AND REGULATIONS 

(1) All tenants are required to present their Building Identification Card to Security upon entering the premises at all times. Firms with
multiple locations must present management with a listing of company employees. These firms will then present their company identification card, sign–in and receive a temporary Identification badge. 

(2) The sidewalks, entrances, passages, courts, elevators, vestibules, stairways, corridors and halls shall not be obstructed or encumbered by
Tenant or used for any purpose other than access to the Premises and for delivery of supplies and equipment in prompt and efficient manner, using elevators and passageways designated for such delivery by Landlord. 

(3) No awnings, air-conditioning units, fans or other projections shall be attached to the outside walls of the Building. 

(4) No curtains, blinds, shades or screens, other than those conforming to Building standards as established by Landlord from time to time,
shall be attached to or hung in, or used in connection with, any window or door of the Premises. All electrical fixtures hung in offices of spaces along the perimeter of the Premises must be of a quality, type, design and bulb color approved by
Landlord, which approval shall not be unreasonably withheld, conditioned or delayed. 
 (5) No sign, advertisement, notice or other
lettering shall be exhibited, inscribed, painted or affixed by Tenant on any part of the outside of the Premises or Building or on the inside of the Premises if the same can be seen from the outside of the Premises without in each case the prior
written consent of Landlord. The foregoing provisions are subject in all respects to Article 31. 
 (6) The exterior windows and doors that
reflect or admit light and air into the Premises or the halls, passageways or other public places in the Building shall not be covered or obstructed by Tenant. 

(7) Except as otherwise provided in this Lease, no showcases or other articles shall be put in front of or affixed to any part of the exterior
of the Building, nor placed in the halls, corridors or vestibules, nor shall any article obstruct any air-conditioning supply or exhaust without the prior written consent of Landlord. 

(8) The water and janitors closets and other plumbing fixtures shall not be used for any purposes other than those for which they were
designed, and no sweepings, rubbish, rags, acids or other substances shall be deposited therein. All damages resulting from any misuse of the fixtures shall be borne by Tenant. 

  
 F-1 

 (9) Tenant shall not make, or permit to be made, any unseemly or disturbing notices or disturb or
interfere with occupants of the Building or neighboring buildings or those having business with them. 
 (10) Tenant, or any of
Tenant’s employees, agents, visitors or licensees, shall not at any time bring or keep upon the Premises any inflammable, combustible or explosive fluid, chemical or substance except such as are incidental to usual office occupancy. 

(11) No additional locks or bolts of any kind shall be placed upon any of the doors or windows by Tenant, nor shall any changes be made in
existing locks or the mechanism thereof, unless Tenant promptly provides Landlord with the key or combination thereto. Tenant shall, upon the termination of its tenancy, return to Landlord all keys for any locks in the Premises and for all toilet
rooms, and in the event of the loss of any keys furnished at Landlord’s expense, Tenant shall pay to Landlord the cost thereof. 
 (12)
No bicycles, vehicles or animals (except for seeing eye dogs) shall be brought into or kept by Tenant in or about the Premises or the Building. 

(13) All removals, or the carrying in or out of any safes, freight, furniture or bulky matter of any description must take place in the manner
and during the hours, which Landlord or its agent reasonably may determine from time to time and by movers approved in advance by Landlord or its agent, which approval shall not be unreasonably withheld, conditioned or delayed. Landlord reserves the
right to inspect all safes, freight or other bulky articles to be brought into the Building and, except to the extent that Tenant leases any retail space in the Building, to exclude from the Building all safes, freight or other bulky articles which
violate any of these Rules and Regulations or the Lease of which these Rules and Regulations are apart. 
 (14) Tenant shall not occupy or
permit any portion of the Premises to be occupied for the possession, storage, manufacture or sale of liquor or narcotics. Tenant shall not engage or pay any employees on the Premises, except those actually working for Tenant at the Premises, nor
advertise for labor giving an address at the Premises. 
 (15) Tenant shall not purchase water, ice, towels or other like services, or
accept barbering or shoe shining services in the Premises, from any company or persons not approved by Landlord, provided that such approval shall not be unreasonably withheld, conditioned or delayed, nor at hours and under regulations other than as
reasonably fixed by Landlord. 
 (16) Intentionally Omitted. 

(17) Except for Tenant’s customers in any retail space leased by Tenant, Landlord reserves the right to exclude from the Building at all
times other than Operating Hours all persons who do not present a pass to the Building signed or approved by Landlord. Tenant shall be responsible for all persons for whom a pass is issued at the request of Tenant and shall be liable to Landlord for
all acts of such persons. 

  
 F-2 

 (18) Tenant shall, at its expense, provide electricity and light for the employees of Landlord
doing janitor service or other cleaning, or making repairs or alterations in the Premises. 
 (19) The requirements of Tenant will be
attended to only upon written application at the Office of the Building. Building employees shall not perform any work or do anything outside of their regular duties, unless under special instructions from the office of Landlord. 

(20) Canvassing, soliciting and peddling in the Building is prohibited and Tenant shall cooperate to prevent the same. 

(21) There shall not be used in the Building, either by Tenant or by jobbers or others, any hand trucks except those equipped with rubber
tires and side guards. Carts and hand trucks of any kind are prohibited in all passenger elevators. All damages resulting from any misuse of the elevators shall be borne by Tenant. 

(22) Except as set forth in Article 5, Tenant shall not do any cooking, conduct any restaurant, luncheonette or cafeteria for the sale
or service of food or beverages to its employees or to others, or cause or permit any odors of cooking or other processes or any unusual or objectionable odors to emanate from the Premises. 

(23) Tenant shall keep the entrance door to the Premises closed at all times. 

(24) Tenant shall comply with Landlord’s rules as promulgated from time to time regarding separation of various types of trash. The
amount of any fines incurred by Landlord by reason of Tenant’s failure to comply shall be paid by Tenant to Landlord upon demand as Additional Rent. 

(25) The design and decoration of the elevator areas of each floor of the Premises and the public corridors of any floor of the Premises
occupied by more than one (1) occupant shall be under the sole control of Landlord and Tenant shall not place anything whatsoever therein. 

(26) Smoking within the building is prohibited. 

(27) There shall be no storage of any kind allowed in the freight elevator lobby at any time. Storage of any kind is prohibited by law and is
subject to monetary penalties. 
 (28) Roller blades are prohibited in the building and plaza areas. 

  
 F-3 

 SCHEDULE G 

FORM OF NON-DISTURBANCE AGREEMENT 

SUBORDINATION, NON-DISTURBANCE 

AND ATTORNMENT AGREEMENT 

THIS AGREEMENT, made and entered into as of the      day of
             2010, by and among THE UNION LABOR LIFE INSURANCE COMPANY, with its principal office at 8403 Colesville Road, Thirteenth Floor, Silver Spring, Maryland 20910 (hereinafter
called “Mortgagee”), FORRESTER RESEARCH, INC., a Delaware corporation, having an address at 400 Technology Square, Cambridge, Massachusetts 02139 (hereinafter called “Lessee”), and RFL 160 FIFTH LLC, a Delaware
limited liability company, having an address c/o RFR Holding LLC, 400 Park Avenue, 3rd Floor, New York, New York 10022 (hereinafter called “Owner”). 

WITNESSETH: 
 WHEREAS,
Owner is the owner of a leasehold interest in the improved real property described in Schedule A annexed hereto (the “Premises”); and 

WHEREAS, Lessee has by a written lease dated as of the     day of April 2010 (hereinafter called the
“Lease”) leased from Owner a portion of the Premises identified as the entire third floor (the “Demised Premises”); and 

WHEREAS, Mortgagee is the owner and holder of a mortgage encumbering the Premises as security for a loan from Mortgagee to Owner (the
“Mortgage”); and 
 WHEREAS, Lessee and Mortgagee have agreed to the following with respect to their mutual rights and
obligations pursuant to the Lease and the Mortgage. 
 NOW, THEREFORE, for and in consideration of Ten Dollars ($10.00) paid by each party
to the other and the mutual covenants and agreements herein contained and other good and valuable consideration, the receipt whereof is hereby acknowledged, the parties hereto do hereby covenant and agree as follows: 

A. Lessee’s interest in the Lease and all rights of Lessee thereunder shall be and are hereby declared subject and subordinate to the
Mortgage upon the Premises and its terms, and the term “Mortgage” as used herein shall also include any amendments, increases, renewals, modifications, consolidations, spreaders, replacements, combinations, supplements, substitutions and
extensions thereof, now or hereafter made. 
 B. In the event of any foreclosure of the Mortgage or any conveyance in lieu of foreclosure,
provided that the Lessee shall not then be in default beyond any grace period under the Lease, Lessee shall not be made a party in any action or proceeding to remove or evict Lessee or to disturb its possession, nor shall the leasehold estate of
Lessee created by the Lease be affected in any way, and the Lease shall continue in full force and effect as a direct lease between Lessee and Mortgagee, subject to the provisions hereof. 

  
 G-1 

 C. After the receipt by Lessee of notice from Mortgagee of any foreclosure of the Mortgage or any
conveyance in lieu of foreclosure, Lessee will thereafter attorn to and recognize Mortgagee as its substitute Owner, and having thus attorned, Lessee’s possession shall not thereafter be disturbed provided, and so long as, Lessee shall continue
to timely pay all rentals under the Lease and otherwise observe and perform the covenants, terms and conditions of the Lease. 
 D. Lessee
hereby agrees to provide Mortgagee with prompt notice of any asserted default by Owner of its obligations under the Lease. In the event any such asserted default constitutes a legal basis for the cancellation of the Lease by Lessee, Lessee hereby
agrees that the Lease shall not be canceled or terminated until Mortgagee shall have a reasonable period of time within which to obtain possession of the Premises, and cure such default. 

E. Lessee and Owner hereby agree that, in the event that Mortgagee delivers to a notice stating that an Event of Default (as defined in the
Mortgage) has occurred under the Mortgage or any other document executed in connection therewith and requesting that all rent and additional rent due under the Lease be thereafter paid to Mortgagee, Lessee shall pay, and is hereby authorized and
directed by Owner to pay, such rent and additional rent directly to Mortgagee. Delivery to Lessee of the aforedescribed notice from Mortgagee shall be conclusive evidence of the right of Mortgagee to receive such rents and payment of the rents by
Lessee to Mortgagee pursuant to such notice shall constitute performance in full of Lessee’s obligation under the Lease to pay such rents to Owner. If and to the extent that the Lease or any provision of law shall entitle Lessee to notice of
any mortgage, Lessee acknowledges and agrees that this Agreement shall constitute such notice to Lessee of the existence of the Mortgage. Lessee acknowledges that it has notice that the Lease and the rent and all other sums due thereunder have been
assigned to Mortgagee as part of the security for the loan to Owner. 
 F. No conveyance of Owner’s interest in the Premises or any
part thereof to Lessee shall, insofar as Mortgagee is concerned, cause the estate encumbered by the Mortgage and leasehold estate created by the Lease to merge, rather said estates shall remain separate and distinct and the Lease shall continue in
full force and effect notwithstanding the vesting of said estates in any single person or entity by reason of such conveyance or otherwise. 

G. Lessee hereby agrees that notwithstanding anything to the contrary in this Agreement or the Lease: 

(a) The Lease may not be amended, altered, terminated or, except as permitted without Landlord’s consent pursuant to Article 15 of
the Lease, assigned or sublet without the prior written consent of Mortgagee and no such amendment, modification, termination, assignment or sublease of the Lease shall be effective against Mortgagee, unless consented to in writing by Mortgagee;

 (b) Mortgagee shall not be bound by any advance payment of rent or additional rent to Owner in excess of one month’s prepayment
thereof, in the case of rent, or in excess of one periodic payment in advance, in the case of additional rent, unless expressly approved in writing by Mortgagee; 

  
 G-2 

 (c) Nothing herein contained shall impose any obligation upon Mortgagee to perform any of the
obligations of Owner under the Lease, unless and until Mortgagee shall take possession of the Premises, and, in any event, Mortgagee shall have no liability with respect to any acts or omissions of Owner occurring prior to the date on which
Mortgagee shall take possession of the Premises. 
 (d) In no event shall Mortgagee be liable for any act or omission of the Owner, nor
shall Mortgagee be subject to any offsets (except as expressly set forth in the Lease) or deficiencies which Lessee may be entitled to assert against the Owner as a result of any act or omissions of Owner occurring prior to Mortgagee’s
obtaining possession of the premises. 
 (e) Notwithstanding anything to the contrary contained herein, officers, directors, shareholders,
agents, servants and employees of Mortgagee shall have no personal liability to Lessee and the liability of Mortgagee, in any event, shall not exceed and shall be limited to Mortgagee’s interest in the Premises. 

(f) Mortgagee shall not be bound by any covenant to undertake or complete any construction of the Premises, the Demised Premises or any
portion thereof; 
 (g) Mortgagee shall not be bound by any obligation of Owner to make any payment to Lessee, except that Mortgagee shall
be liable for the timely return of any security or other deposit actually received by Mortgagee and Mortgagee shall be liable on account of any prepayments of rent or other charges owing to Lessee if the funds are actually received by Mortgagee; and

 (h) Mortgagee shall not be bound by any obligation to repair, replace, rebuild or restore the Premises, the Demised Premises, or any part
thereof, in the event of damage by fire or other casualty, or in the event of partial condemnation. 
 H. Any options or rights contained in
the Lease to acquire title to the Premises or any portion thereof, including any right of first refusal, right of first offer, or similar provisions, shall not apply to a foreclosure sale of the Premises by Mortgagee pursuant to its rights under the
Mortgage and shall be extinguishable by any foreclosure of the Mortgage. Any right of Lessee to cancel the Lease in order to move to other property to be leased or purchased from Owner and any right of Lessee to inducements to be provided by Owner
but not set forth in the Lease shall be extinguishable by any foreclosure of the Mortgage. 
 I. Each of Owner and Lessee represents and
warrants to Mortgagee that, as of the date hereof, there are no agreements other than the Lease in existence or contemplated between Owner and Lessee, relating to the Premises or the Demised Premises or with respect to any other matter related to
Lessee’s occupancy of the Demised Premises. 
 J. Owner, by its execution of this Agreement, agrees to be bound by and to act in
accordance with the terms and conditions hereinabove contained. 
 K. This Agreement and its terms shall be binding upon and inure to the
benefit of the parties hereto and their respective successors and assigns, including without limitation, any purchaser at any foreclosure sale. All references to any party hereto shall include such party’s successors and assigns. 

  
 G-3 

 [SIGNATURES APPEAR ON THE FOLLOWING PAGE] 

  
 G-4 

 IN WITNESS WHEREOF, this Agreement has been fully executed under seal on the day and year
first above written. 
  

			
	MORTGAGEE:
	
	THE UNION LABOR LIFE INSURANCE COMPANY, a Maryland corporation
		
	By:	 	  

	Name:	 	  

	Title:	 	  

	
	LESSEE:
	
	FORRESTER RESEARCH, INC., a Delaware corporation
		
	By:	 	  

	Name:	 	  

	Title:	 	  

	
	OWNER:
	
	RFL 160 FIFTH LLC, a Delaware Limited Liability company
		
	By:	 	  

	Name:	 	  

	Title:	 	  

  
 G-5 

							
	STATE OF                     	 	)	 		  	
		 	)	 	ss.:	  	
	COUNTY OF                     	 	)	 		  	

 On the      day of
             in the year 20    , before me, the undersigned, personally appeared
                                        ,
personally known to me or proved to me on the basis of satisfactory evidence to be the individual whose name is subscribed to the within instrument and acknowledged to me that he executed the same in his capacity, and that by his signature on the
instrument, the individual, or the person upon behalf of which the individual acted, executed the instrument. 
  

	
	  

	                    , Notary Public

 

			
	My commission expires:	 	  

  

							
	STATE OF                     	 	)	 		  	
		 	)	 	ss.:	  	
	COUNTY OF                     	 	)	 		  	

 On the      day of
             in the year 20    , before me, the undersigned, personally appeared
                                        ,
personally known to me or proved to me on the basis of satisfactory evidence to be the individual whose name is subscribed to the within instrument and acknowledged to me that he executed the same in his capacity, and that by his signature on the
instrument, the individual, or the person upon behalf of which the individual acted, executed the instrument. 
  

			
	  

	                    , Notary Public
		
	My commission expires:	 	  

  

							
	STATE OF                     	 	)	 		  	
		 	)	 	ss.:	  	
	COUNTY OF                     	 	)	 		  	

 On the      day of          in the year
20    , before me, the undersigned, personally appeared
                                        ,
personally known to me or proved to me on the basis of satisfactory evidence to be the individual whose name is subscribed to the within instrument and acknowledged to me that he executed the same in his capacity, and that by his signature on the
instrument, the individual, or the person upon behalf of which the individual acted, executed the instrument. 
  

			
	  

	                    , Notary Public
		
	My commission expires:	 	  

  
 G-6 

 Schedule A 

All that certain lot, piece or parcel of land, situate, lying and being in the Borough of Manhattan, City, County and State of New York,
bounded and described as follows: 
 BEGINNING at a point on the northerly side of West 42nd Street, distant 208 feet easterly from the
northeasterly corner of 42nd Street and Avenue of the Americas (formerly 6th Avenue); 
 RUNNING THENCE easterly along the northerly side of
42nd Street, 234 feet; 
 THENCE northerly parallel with Avenue of the Americas, 200 feet 10 inches to the southerly side of 43rd Street;

 THENCE westerly along the southerly side of 43rd Street, 442 feet to the easterly side of Avenue of the Americas; 

THENCE southerly along the easterly side of Avenue of the Americas, 100 feet 5 inches to the center line of the block; 

THENCE easterly parallel with 42nd Street, 208 feet; 

THENCE southerly parallel with Avenue of the Americas, 100 feet 5 inches to the northerly side of 42nd Street, at the point or place of
BEGINNING. 

  
 G-7 

 SCHEDULE H 

COMMENCEMENT DATE AGREEMENT 

AGREEMENT made as of the      day of             ,
20    , between RFL 160 FIFTH LLC, a Delaware limited liability company, having an address at c/o RFR Holding LLC, 390 Park Avenue, 3rd Floor, New York, New York 10022, as
Landlord, and FORRESTER RESEARCH, INC., a Delaware corporation, having an address at 400 Technology Square, Cambridge, Massachusetts 02139, as Tenant. 

W I T N E S S E T H: 
 WHEREAS,
Landlord and Tenant have entered into an Agreement of Lease, dated as of April     , 20     (the “Lease”), pursuant to which Landlord leased to Tenant certain space in the Building known as
160 Fifth Avenue, New York, New York, as more fully described in the Lease; and 
 WHEREAS, pursuant to the provisions of the Lease, the
parties agreed to execute a written agreement confirming the Commencement Date, the Rent Commencement Date and the Fixed Expiration Date of the Lease. 

NOW, THEREFORE, Landlord and Tenant confirm that the “Term” of the Lease has commenced on
                 , 20    , and that such date constitutes the “Commencement Date” of the Lease; that the “Rent Commencement Date”
is                  , 20    ; and that the Term of the Lease will expire on             
    , 20    , and that such date constitutes the “Fixed Expiration Date” of the Lease, as such quoted terms are defined in the Lease. 

  
 H-1 

 IN WITNESS WHEREOF, Landlord and Tenant have respectively executed this Commencement Date
Agreement as of the day and year first above written. 
  

			
	LANDLORD:
	
	 RFL 160 FIFTH LLC,
 a Delaware
limited liability company

		
	By:	 	  

		 	 Aby Rosen [or Michael Fuchs]
 Managing
Member

	
	TENANT:
	
	By: FORRESTER RESEARCH, INC., a Delaware corporation
	
	  

	Name:	 	
	Title:	 	

  
 H-2 

 SCHEDULE I 

CURRENT BUILDING HOLIDAYS 
  

					
		  	 •      New Years Day;
	  	
			
		  	 •      Presidents Day;
	  	
			
		  	 •      Good Friday;
	  	
			
		  	 •      Memorial Day;
	  	
			
		  	 •      Independence Day;
	  	
			
		  	 •      Labor Day;
	  	
			
		  	 •      Columbus Day;
	  	
			
		  	 •      Thanksgiving Day;
	  	
			
		  	 •      Day after Thanksgiving Day;
	  	
			
		  	 •      Christmas Day; and
	  	
		
		  	 •      One (1) floating holiday (either MLK day, Yom Kippur, Eid al-Fitr or
September 11th).

  
 I-1 

 SCHEDULE J 

PRE-EXISTING RIGHTS 
 The following rights
granted to The Simons Foundation, Inc. (“Simons”) pursuant to a lease dated October 5, 2009 (as amended by a First Amendment of Lease, dated as of April 7, 2010): (i) a one-time option to lease one additional full
floor in the Building (which shall be either the fourth floor or the fifth floor) commencing on or about January 1, 2021, subject to the renewal right of Prophet Brand Strategy (“Prophet”), the existing tenant on the fifth
floor of the Building (the “Fifth Floor Space”), pursuant to the express terms and conditions of its lease; and (ii) an option to renew its lease for a period of five (5) years. 

The following rights granted to Prophet pursuant to a lease dated December 7, 2009: (a) a one-time option to lease office space (as opposed to
retail space) of a floor of the Building which is contiguous to the Fifth Floor Space (provided that such space may include other office space in the Building marketed by Landlord together therewith, even if such other office space is not on a floor
contiguous to the Fifth Floor Space), commencing on or after April 1, 2013, subject to the rights of Simons; and (b) an option to renew its lease for a period of five (5) years. 

  
 J-1 

 SCHEDULE K 

TEMPORARY CERTIFICATE OF OCCUPANCY 
  

					
	

	 		 	Page 1 of 3
	 	Certificate of Occupancy	 	
	 		 	  
 CO
Number:            104894535T002

 This certifies that the premises described herein conforms substantially to the approved plans and specifications and to the
requirements of all applicable laws, rules and regulations for the uses and occupancies specified. No change of use or occupancy shall be made unless a new Certificate of Occupancy is issued. This document or a copy shall be available for
inspection at the building at all reasonable times. 
  

													
	A.	    	Borough: Manhattan	 		  	Block Number:	 	     00822	  	  Certificate Type:	  	Temporary
							
		    	Address:  160 FIFTH AVENUE	 		  	Lot Number(s):	 	     39	  	  Effective Date:	  	02/19/2010
					
		    	Building Identification Number (BIN): 1015500	 		  	  Expiration Date:	  	05/20/2010
							
		    		 		  	Building Type:	 	     Altered	  		  	
		
		    	For zoning lot metes & bounds, please see BISWeb.
					
	B.	    	Construction classification:	 	1	  		 	(Prior to 1968 Code)
				
		    	Building Occupancy Group classification:	 	COM	 	(Prior to 1968 Code)
				
		    	Multiple Dwelling Law Classification:	 	None	 	
					
		    	No. of stories: 9	 	Height in feet: 110	 		  	No. of dwelling units: 0
					
	C.	    	Fire Protection Equipment:	 		 		  	
		    	None associated with this filing.	 		 		  	
					
	D.	    	 Type and number of open spaces:
 None
associated with this filing.
	 		 		  	
		
	E.	    	 This Certificate is issued with the following legal limitations:

None

		
		    	 Outstanding requirements for obtaining Final Certificate of Occupancy:

There are 16 outstanding requirements. Please refer to BISWeb for further detail.
  

Borough Comments: None

  

					
			
	

	 		 	

	Borough Commissioner	 		 	Commissioner
	
	DOCUMENT CONTINUES ON NEXT PAGE

K-1 

  

					
	

	 		 	Page 2 of 3
	 	Certificate of Occupancy	 
	 	  
 CO
Number:             104894535T002

  

 Permissible Use and Occupancy 

All Building Code occupancy group designations are 1968 designations, except RES, COM, or PUB which 

are 1938 Building Code occupancy group designations. 
  

													
	 Floor
From To
	    	 Maximum
 persons

permitted
	    	 Live load
lbs per

sq. ft
	    	 Building
 Code

occupancy

group
	    	 Dwelling or

Rooming

Units
	    	 Zoning
use group
	    	 Description of use

	CEL	    	0	    	OG	    	D-2	    		    		    	BOILER, RETAIL, STORAGE, MECHANICAL
		    		    		    	C	    		    		    	ROOMS, TANK ROOM
		    		    		    	B-2	    		    		    	
	CEL	    	21	    		    	B-2	    		    		    	STORAGE ROOM
							
	CEL	    	154	    		    	C	    		    	6	    	RETAIL
							
	001	    	386	    	100	    	C	    		    	6	    	RETAIL STORES, LOBBY
							
	002	    	204	    	100	    	C	    		    	6	    	RETAIL
							
	002	    		    		    	D-2	    		    	6	    	MECHANICAL ROOM
							
	003	    	95	    	100	    	E	    		    	6	    	OFFICES_MECHANICAL ROOM
							
	004	    	95	    	100	    	E	    		    	6	    	OFFICES, MECHANICAL ROOM
							
	005	    	95	    	100	    	E	    		    	6	    	OFFICES, MECHANICAL ROOM
							
	006	    	95	    	100	    	E	    		    	6	    	OFFICES, MECHANICAL ROOM
							
	007	    	95	    	100	    	E	    		    	6	    	OFFICES, MECHANICAL ROOM
							
	008	    	96	    	100	    	E	    		    	6	    	OFFICES, MECHANICAL ROOM
							
	009	    	96	    	100	    	E	    		    	6	    	OFFICES, MECHANICAL ROOM

  

					
			
	

	 		 	

	Borough Commissioner	 		 	Commissioner
	
	DOCUMENT CONTINUES ON NEXT PAGE

K-2 

  

					
	

	 		 	Page 3 of 3
	 	Certificate of Occupancy	 
	 	  
 CO
Number:             104894535T002

 NOTE: ACCESSORY STORAGE LIMITED TO 2500 SQUARE FEET PER ESTABLISHMENT NOTE: FIRE DEPARTMENT APPROVALS: 

STANDPIPE SYSTEM • FEBRUARY 27, 1941 SPRINKLER SYSTEM • MARCH 27, 1967 FUEL OIL INSTALLATION • AUGUST 22, 1040 

END OF SECTION 
  

					
	

	 		 	

	Borough Commissioner	 		 	Commissioner

					
			
		 	END OF DOCUMENT	 	104894535/002    2/19/2010  8:49:51  AM

  
 K-3EX-10.30

 Exhibit 10.30 

OFFICE LEASE 
 150 SPEAR
STREET, SAN FRANCISCO, CALIFORNIA 
 150 SPEAR STREET, LLC, 

a Delaware limited liability company, 

as Landlord, 
 and 

FORRESTER RESEARCH, INC., 
 a
Delaware corporation 
 as Tenant 

 TABLE OF CONTENTS 

 

					
	 ARTICLE 1 PREMISES, BUILDING, PROJECT, AND COMMON AREAS
	  	 	1	  
	 ARTICLE 2 LEASE TERM
	  	 	2	  
	 ARTICLE 3 BASE RENT
	  	 	4	  
	 ARTICLE 4 ADDITIONAL RENT
	  	 	4	  
	 ARTICLE 5 USE OF PREMISES
	  	 	9	  
	 ARTICLE 6 SERVICES AND UTILITIES
	  	 	12	  
	 ARTICLE 7 REPAIRS
	  	 	13	  
	 ARTICLE 8 ADDITIONS AND ALTERATIONS
	  	 	14	  
	 ARTICLE 9 COVENANT AGAINST LIENS
	  	 	16	  
	 ARTICLE 10 INSURANCE
	  	 	17	  
	 ARTICLE 11 DAMAGE AND DESTRUCTION
	  	 	19	  
	 ARTICLE 12 NONWAIVER
	  	 	20	  
	 ARTICLE 13 CONDEMNATION
	  	 	21	  
	 ARTICLE 14 ASSIGNMENT AND SUBLETTING
	  	 	21	  
	 ARTICLE 15 SURRENDER OF PREMISES; OWNERSHIP AND REMOVAL OF TRADE FIXTURES
	  	 	25	  
	 ARTICLE 16 HOLDING OVER
	  	 	26	  
	 ARTICLE 17 ESTOPPEL CERTIFICATES
	  	 	26	  
	 ARTICLE 18 SUBORDINATION
	  	 	27	  
	 ARTICLE 19 DEFAULTS; REMEDIES
	  	 	28	  
	 ARTICLE 20 COVENANT OF QUIET ENJOYMENT
	  	 	30	  
	 ARTICLE 21 SECURITY DEPOSIT
	  	 	31	  
	 ARTICLE 22 SIGNS
	  	 	31	  
	 ARTICLE 23 COMPLIANCE WITH LAW
	  	 	32	  
	 ARTICLE 24 LATE CHARGES
	  	 	33	  
	 ARTICLE 25 LANDLORD’S RIGHT TO CURE DEFAULT; PAYMENTS BY TENANT
	  	 	33	  
	 ARTICLE 26 ENTRY BY LANDLORD
	  	 	33	  
	 ARTICLE 27 TENANT PARKING
	  	 	34	  
	 ARTICLE 28 MISCELLANEOUS PROVISIONS
	  	 	35	  
		
	 EXHIBIT A – OUTLINE OF PREMISES
	  			
	 EXHIBIT B – TENANT’S WORK LETTER
	  			
	 EXHIBIT C – NOTICE OF LEASE TERM DATES
	  			
	 EXHIBIT D – RULES AND REGULATIONS
	  			
	 EXHIBIT E – SITE PLAN SHOWING CORRIDORS ON 11TH FLOOR
	  			
		
	 ADDENDUM 1 – RIGHT OF FIRST OFFER
	  			
	 ADDENDUM 2 – ROOFTOP SPACE
	  			

  
 (i) 

 150 SPEAR STREET, SAN FRANCISCO, CALIFORNIA 

OFFICE LEASE 
 This
Office Lease (the “Lease”), dated as of the date set forth in Section 1 of the Summary of Basic Lease Information (the “Summary”), below, is made by and between 150 Spear Street, LLC, a Delaware limited
liability company (“Landlord”), and Forrester Research, Inc., a Delaware corporation (“Tenant”). 

SUMMARY OF BASIC LEASE INFORMATION 
  

							
	 	 	TERMS OF LEASE 	  	DESCRIPTION
			
	1.    	 	Date:	  	November 24, 2010
		
	2.	 	Premises
				
		 	2.1    	 	Building:	  	150 Spear Street, San Francisco, California
				
		 	2.2	 	Premises:	  	Approximately 15,560 rentable square feet of space located on the eleventh (11th) floor of the Building and commonly known as Suite 1100, as further set forth in Exhibit A to this Lease.
				
		 	2.3	 	Project:	  	The Building is part of an office project known as 150 Spear Street, San Francisco, California, as further set forth in Section 1.1.2 of this Lease.
		
	3.	 	Lease Term
 (Article 2)

				
		 	3.1	 	Length of Term:	  	Sixty-three (63) full calendar months.
				
		 	3.2	 	Estimated Lease Commencement Date:	  	April 1, 2011
				
		 	3.3	 	Estimated Lease Expiration Date:	  	June 30, 2016
			
	4.	 	Base Rent (Article 3):	  	

  

									
	 Months of Lease Term
	  	Annual
Base Rent Per Square Foot	 	  	Monthly
Installment
of Base Rent	 
			
	 Months 1-12*
	  	$	35.00 psf	  	  	$	45,383.33	  
			
	 Months 13-24
	  	$	36.00 psf	  	  	$	46,680.00	  
			
	 Months 25-36
	  	$	37.00 psf	  	  	$	47,976.67	  
			
	 Months 37-48
	  	$	38.00 psf	  	  	$	49,273.33	  
			
	 Months 49-63
	  	$	39.00 psf	  	  	$	50,570.00	  

  

	*	Base Rent for the first (1st) through third (3rd) full months of the initial Lease Term shall be abated
pursuant to the terms of Section 3.2 of this Lease. 

  
 BLI - 1 

							
	5.    	 	 Base Year
 (Article 4):
	  	Calendar year 2011.
			
	6.	 	 Tenant’s Share
 (Article
4):
	  	Approximately 5.94% (15,560 rsf of Premises/262,047 rsf of Building).
			
	7.	 	 Permitted Use
 (Article 5):
	  	Subject to the limitations imposed under Section 5 of this Lease, general office use only.
			
	8.	 	 Security Deposit
 (Article
21):
	  	$0.00
			
	9.	 	 Parking Spaces
 (Article
27):
	  	One.
			
	10.	 	 Address of Tenant for Notices

(Section 28.19):
	  	 Forrester Research, Inc.
 400 Technology
Square
 Cambridge, MA 02139
 Attention: Chief Financial
Officer
  
 and
  

Forrester Research, Inc.
 400 Technology Square

Cambridge, MA 02139
 Attention: Chief Legal Officer

 
 with a courtesy copy (which shall not be required for receipt of notices hereunder)
to:
  
 Dionne & Gass LLP

131 Dartmouth Street
 Suite 501

Boston, MA 02116
 Attention: Joanne A. Robbins, Esq.

			
	11.	 	Address of Landlord	  	
				
		 	11.1    	 	 Address of Landlord for Notices
 (Section
28.19):
	  	 150 Spear Street, LLC
 c/o Principal Real Estate
Investors
 801 Grand Avenue – Department H-137
 Des
Moines, IA 50392-1370
 Attn: Western CRE-Equities Team
  

with a copy to:
  

Pacific Eagle Holdings Corporation
 3000 Executive Parkway, Suite
236
 San Ramon, California 94583
 Attn: David
Hennefer

  
 BLI - 2 

							
				
		 	11.2    	 	 Address of Landlord for Rent Payments
 (Article
3):
	  	 150 Spear Street, LLC
 Property: 122610

P.O. Box 310300
 Des Moines, IA 50331-0300

			
	12.    	 	 Broker(s)
 (Section 28.25):
	  	Colliers International representing Landlord and Richards, Barry, Joyce and Partners, LLC and Cornish & Carey, representing Tenant.

  
 BLI - 3 

 ARTICLE 1 

Premises, Building, Project, and Common Areas 

1.1 Premises, Building, Project and Common Areas. 

1.1.1 The Premises. Landlord hereby leases to Tenant and Tenant hereby leases from Landlord the premises set forth in
Section 2.2 of the Summary (the “Premises”). The outline of the Premises is set forth in Exhibit A attached hereto and the Premises contain approximately the number of rentable square feet as set forth in
Section 2.2 of the Summary. The parties hereto agree that the lease of the Premises is upon and subject to the terms, covenants and conditions herein set forth, and Tenant covenants as a material part of the consideration for this Lease to keep
and perform each and all of such terms, covenants and conditions by it to be kept and performed and that this Lease is made upon the condition of such performance. The parties hereto hereby acknowledge that the purpose of Exhibit A is
to show the approximate location of the Premises in the “Building,” as that term is defined in Section 1.1.2 below, only, and such Exhibit is not meant to constitute an agreement, representation or warranty as to the construction of
the Premises, the precise area thereof or the specific location of the “Common Areas,” as that term is defined in Section 1.1.3 below, or the elements thereof or of the accessways to the Premises or the “Project,” as that
term is defined in Section 1.1.2 below. Except as specifically set forth in this Lease and in the Tenant Work Letter attached hereto as Exhibit B (the “Tenant Work Letter”), Landlord shall not be obligated to
provide or pay for any improvement work or services related to the improvement of the Premises. Tenant also acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty regarding the condition of the Premises,
the Building or the Project or with respect to the suitability of any of the foregoing for the conduct of Tenant’s business, except as specifically set forth in this Lease and the Tenant Work Letter. The taking of possession of the Premises by
Tenant shall conclusively establish that the Premises and the Building were at such time in good and sanitary condition and repair (with the exception of latent defects). 

1.1.2 The Building and the Project. The Premises are a part of the building set forth in Section 2.1 of the Summary (the
“Building”). The Building is part of an office project known as 150 Spear Street, San Francisco, California. The term “Project,” as used in this Lease, shall mean (i) the Building and the Common Areas, and
(ii) the land (which is improved with landscaping, parking facilities and other improvements) upon which the Building and the Common Areas are located. 

1.1.3 Common Areas. Tenant shall have the non-exclusive right to use in common with other tenants in the Project, and subject to
the rules and regulations referred to in Article 5 of this Lease, those portions of the Project which are provided, from time to time, for use in common by Landlord, Tenant and any other tenants of the Project (such areas are collectively referred
to herein as the “Common Areas”). The Common Areas shall be maintained and operated by Landlord in a manner consistent with other comparable office buildings in the vicinity of the Building, and the use thereof shall be subject to
such reasonable rules, regulations and restrictions as Landlord may make from time to time, provided that Tenant shall not be bound by any such rules and regulations of which it has not been given reasonable prior notice and provided further that
all such rules and regulations shall be enforced in a non-discriminatory manner. Landlord reserves the right to close temporarily, make alterations or additions to, or change the location of elements of the Project and the Common Areas; provided,
however, that no such closure, alteration, addition or change, unless required as a result of an emergency or by Applicable Law, shall materially and adversely affect Tenant’s rights hereunder. 

1.2 Rentable Square Feet of Premises and Building. For purposes of this Lease, “rentable square feet” in the
Premises, the Building and the Project, as the case may be, shall be calculated in accordance with the Standard Method for Measuring Floor Area for Office Buildings, ANSI Z65.1-1996, promulgated by the Building Owners And Managers Association (BOMA)
(“Measurement Standard”). Notwithstanding anything to the contrary set forth in Section 2.2 of the Summary or elsewhere in this Lease, the rentable area of the Premises and any ROFO Spaces (as defined in Addendum 1) is subject
to verification by Landlord’s space planner pursuant to the Measurement Standard from time to time (the “Measurement Verification”). In the event that Landlord’s space planner determines that the

  
 1 

 
rentable area of the Premises shall be different from that set forth in Section 2.2 of the Summary, then all amounts, percentages and figures appearing or referred to in this Lease based
upon such incorrect rentable area (including, without limitation, the amounts of “Base Rent,” the “Tenant Improvement Allowance,” and “Tenant’s Share,” as those terms are defined in this Lease, respectively) shall
be modified in accordance with such determination. Notwithstanding the foregoing, if Tenant notifies Landlord that Tenant objects to the Measurement Verification within thirty (30) days after Tenant’s receipt of the Measurement
Verification from Landlord, then, at Tenant’s sole cost and expense, the Premises shall be measured by an independent architect jointly selected by Landlord and Tenant and, if applicable, all amounts, percentages and figures appearing or
referred to in this Lease based upon such incorrect rentable area (including, without limitation, the amounts of “Base Rent,” the “Tenant Improvement Allowance,” and “Tenant’s Share”) shall be modified in
accordance with such determination. Notwithstanding the foregoing, Landlord may remeasure the Building and/or the Project, from time to time, in accordance with the Measurement Standard, and if the rentable area of the Premises, the Building and/or
the Project shall change as measured in such remeasurement, then the rentable area of the Premises and/or the Building, as the case may be, shall be appropriately adjusted as of the date of such remeasurement based upon the written verification by
Landlord’s space planner of such revised rentable area. Any such remeasurement by Landlord shall be subject to verification by Tenant in accordance with this Section 1.2. 

ARTICLE 2 

LEASE TERM 
 2.1
Lease Term. The terms and provisions of this Lease shall be effective as of the date of this Lease. The term of this Lease (the “Lease Term”) shall be for approximately the number of months set forth in
Section 3.1 of the Summary, shall commence on the date (the “Lease Commencement Date”) which is the earlier to occur of (i) April 1, 2011, or (ii) the date Tenant commences business operations in the Premises,
and shall terminate on the date (the “Lease Expiration Date”) which is the last day of the sixty-third (63rd) full calendar month following the Lease Commencement Date,
unless this Lease is sooner terminated as hereinafter provided. For purposes of this Lease, the term “Lease Year” shall mean each consecutive twelve (12) month period during the Lease Term; provided, however, that the last
Lease Year shall end on the Lease Expiration Date. At any time during the Lease Term, Landlord may deliver to Tenant a notice, in substantially the form set forth in Exhibit C attached hereto, as a confirmation only of the information
set forth therein, which Tenant shall execute and return to Landlord within fifteen (15) business days of receipt thereof; provided, however, that Tenant’s failure to execute and return such notice to Landlord within such time shall be
conclusive proof upon Tenant that the information set forth in such notice is as specified therein. Landlord shall permit Tenant to access and enter the Premises upon the mutual execution of this Lease (the “Early Entry Date”),
solely for purposes of installing the Tenant Improvements. In no event may Tenant conduct its business or operations from the Premises until the Lease Commencement Date. Such limited purpose entry and use of the Premises by Tenant shall be at
Tenant’s sole risk and shall also be subject to all of the provisions of this Lease including, but not limited to, the requirement to obtain the insurance required pursuant to this Lease and to deliver insurance certificates as required herein,
and to pay for all utilities consumed in the Premises on and after the Early Entry Date. Notwithstanding the immediately preceding sentence, Tenant shall not be required to pay Rent (other than any utilities costs incurred) prior to the Lease
Commencement Date. In addition to the foregoing, Landlord shall have the right to impose such additional conditions on Tenant’s early entry as Landlord shall deem reasonably appropriate. If, at any time, there is an Event of Default that
results in termination of the Lease, then any such waiver by Landlord of Tenant’s requirement to pay rental payments shall be null and void, and as a component of Landlord’s recovery set forth in Article 19 of the Lease, Tenant shall
immediately pay to Landlord all rental payments so waived by Landlord. 
 2.2 Option to Extend. 

2.2.1 Grant of Extension Option. Subject to the provisions, limitations and conditions set forth in this Section 2.2,
Tenant shall have one (1) option (“Option”) to extend the Lease Term for five (5) years (the “Extended Term”). 

2.2.2 Tenant’s Option Notice. Tenant shall have the right to deliver written notice to Landlord of its intent to exercise
the Option (the “Option Notice”). If Landlord does not receive an Option Notice from Tenant on a date which is neither more than twelve (12) months nor less than nine (9) months prior to the initial Lease Expiration

  
 2 

 
Date, all rights under this Option shall automatically terminate and shall be of no further force or effect. Upon the proper exercise of the Option, subject to the provisions, limitations and
conditions set forth in Paragraph 2.2.5 below, the initial Lease Term shall be extended for the Extended Term. 
 2.2.3 Establishing
the Initial Monthly Base Rent for the Extended Term. The initial monthly Base Rent for the Extended Term shall be equal to the then Fair Market Rental Rate, as hereinafter defined. As used herein, the “Fair Market Rental Rate”
payable by Tenant for the Extended Term shall mean the Base Rent for the highest and best use for comparable space at which non-equity tenants, as of the commencement of the lease term for the Extended Term, will be leasing non-sublease, non-equity,
unencumbered space comparable in size, location and quality to the Premises for a comparable term, which comparable space is located in the Building and in other comparable first-class buildings in the vicinity of the Building including other
first-class office buildings in the San Francisco Central Business District office market, taking into consideration all free rent and other out-of-pocket concessions generally being granted at such time for such comparable space, including the
condition and value of existing tenant improvements in the Premises. The Fair Market Rental Rate shall include the periodic rental increases that would be included for space leased for the period of the Extended Term. 

If Landlord and Tenant are unable to agree on the Fair Market Rental Rate for the Extended Term within ten (10) days of receipt by
Landlord of the Option Notice for the Extended Term, Landlord and Tenant each, at its cost and by giving notice to the other party, shall appoint a competent and impartial commercial real estate broker (hereinafter “broker”) with at least
ten (10) years’ full-time commercial real estate brokerage experience in the geographical area of the Premises to set the Fair Market Rental Rate for the Extended Term. If either Landlord or Tenant does not appoint a broker within ten
(10) days after the other party has given notice of the name of its broker, the single broker appointed shall be the sole broker and shall set the Fair Market Rental Rate for the Extended Term. If two (2) brokers are appointed by Landlord
and Tenant as stated in this paragraph, they shall meet promptly and attempt to set the Fair Market Rental Rate. In addition, if either of the first two (2) brokers fails to submit their opinion of the Fair Market Rental Rate within the time
frames set forth below, then the single Fair Market Rental Rate submitted shall automatically be the initial monthly Base Rent for the Extended Term and shall be binding upon Landlord and Tenant. If the two (2) brokers are unable to agree
within ten (10) days after the second broker has been appointed, they shall attempt to select a third broker, meeting the qualifications stated in this paragraph within ten (10) days after the last day the two (2) brokers are given to
set the Fair Market Rental Rate. If the two (2) brokers are unable to agree on the third broker, either Landlord or Tenant by giving ten (10) days’ written notice to the other party, can apply to the Presiding Judge of the Superior
Court of the county in which the Premises is located for the selection of a third broker who meets the qualifications stated in this paragraph. Landlord and Tenant each shall bear one-half ( 1⁄2) of the cost of appointing the third broker and of paying the third broker’s fee. The third broker, however selected, shall be a person who has not previously acted in any capacity for either Landlord or
Tenant. Within fifteen (15) days after the selection of the third broker, the third broker shall select one of the two Fair Market Rental Rates submitted by the first two brokers as the Fair Market Rental Rate for the Extended Term. The
determination of the Fair Market Rental Rate by the third broker shall be binding upon Landlord and Tenant. 
 Upon determination of the initial monthly
Base Rent for the Extended Term in accordance with the terms outlined above, Landlord and Tenant shall immediately execute an amendment to this Lease. Such amendment shall set forth the initial monthly Base Rent for the Extended Term and the actual
commencement date and expiration date of the Extended Term and such other terms and conditions as may be mutually agreed-upon by Landlord and Tenant. Tenant shall have no other right to extend the Lease Term under this Section 2.2 unless
Landlord and Tenant otherwise agree in writing. 
 2.2.4 Condition of Premises. If Tenant timely and properly exercises the
Option, in strict accordance with the terms contained herein, Tenant shall accept the Premises in its then “As-Is” condition and, accordingly, Landlord shall not be required to perform any additional improvements to the Premises. 

2.2.5 Limitations On, and Conditions To, Extension Option. The Option provided for herein is personal to Tenant and may not be
assigned, voluntarily or involuntarily, separate from or as part of the Lease (except in connection with a Permitted Transfer). At Landlord’s option, all rights of Tenant under this Section 2.2 shall terminate and be of no force or effect
if any of the following individual events occur or any combination thereof occur: (i) an Event of Default has occurred at any time during the eighteen (18) month period prior to the date Tenant delivers an

  
 3 

 
Option Notice, or an Event of Default exists at the time Landlord receives an Option Notice; and/or (ii) Tenant has assigned its rights and obligations under all or part of the Lease or
Tenant has subleased all or part of the Premises (except in connection with a Permitted Transfer and except for any sublease of any ROFO Space); and/or (iii) Tenant’s financial condition on the date of delivery of the Option Notice is, in
the reasonable judgment of Landlord, not adequate to support Tenant’s obligations under this Lease; and/or (iv) Tenant has failed to exercise properly an Option in a timely manner in strict accordance with the provisions of this
Section 2.2; and/or (v) Tenant no longer has possession of all or any part of the Premises under this Lease (except in connection with a Permitted Transfer and except in connection with any permitted sublease of the ROFO Space), or if this
Lease has been terminated earlier, pursuant to the terms and provisions of this Lease. 
 ARTICLE 3 

BASE RENT 
 3.1
Base Rent. From and after the Lease Commencement Date, Tenant shall pay, without prior notice or demand, to Landlord or Landlord’s agent at the address set forth in Section 11.2 of the Summary, or, at Landlord’s option,
at such other place as Landlord may from time to time designate in writing, by a check for currency which, at the time of payment, is legal tender for private or public debts in the United States of America, base rent (“Base Rent”)
as set forth in Section 4 of the Summary, payable in equal monthly installments in advance on or before the first day of each and every calendar month during the Lease Term, without any setoff or deduction whatsoever. The Base Rent for the
first full month of the Lease Term shall be paid at the time of Tenant’s execution of this Lease. If any Rent payment date (including the Lease Commencement Date) falls on a day of the month other than the first day of such month or if any
payment of Rent is for a period which is shorter than one month, the Rent for any fractional month shall accrue on a daily basis for the period from the date such payment is due to the end of such calendar month or to the end of the Lease Term at a
rate per day which is equal to 1/365 of the applicable annual Rent. All other payments or adjustments required to be made under the terms of this Lease that require proration on a time basis shall be prorated on the same basis. 

3.2 Rent Abatement. Notwithstanding anything to the contrary contained herein and provided that Tenant faithfully performs all
of the terms and conditions of this Lease, and no Event of Default by Tenant occurs hereunder, Landlord hereby agrees that Tenant shall not be required to pay monthly installments of Base Rent for the first (1st) through third (3rd) full months of the initial Lease Term (the “Abatement Period”), with the abated Base Rent to be
equal to One Hundred Thirty-Six Thousand One Hundred Forty-Nine and 99/100 Dollars ($136,149.99) in the aggregate (the “Abated Base Rent”). During the Abatement Period, Tenant shall still be responsible for the payment of all of its
other monetary obligations under this Lease. In the Event of a Default under the terms of this Lease in accordance with the provisions of Article 19 hereof that results in a termination of the Lease, then as a part of the recovery set forth
in Article 19 of this Lease, Landlord shall be entitled to the recovery of all Abated Base Rent that was abated under the provisions of this Article 3. 

ARTICLE 4 

ADDITIONAL RENT 

4.1 General Terms. In addition to paying the Base Rent specified in Article 3 of this Lease, Tenant shall pay with respect to
the Lease Term “Tenant’s Share” of the annual “Direct Expenses,” as those terms are defined in Sections 4.2.6 and 4.2.2 of this Lease, respectively, which are in excess of the amount of Direct Expenses applicable to the
“Base Year,” as that term is defined in Section 4.2.1 below; provided, however, that in no event shall any decrease in Direct Expenses for any Expense Year below Direct Expenses for the Base Year entitle Tenant to any decrease in Base
Rent or any credit against sums due under this Lease. Such payments by Tenant, together with any and all other amounts payable by Tenant to Landlord pursuant to the terms of this Lease, are hereinafter collectively referred to as the
“Additional Rent”, and the Base Rent and the Additional Rent and all other sums payable by Tenant to Landlord hereunder are herein collectively referred to as “Rent.” All amounts due under this Article 4 as Additional Rent shall
be payable for the same periods and in the same manner as the Base Rent. Without limitation on other obligations of Tenant which survive the expiration of the Lease Term, the obligations of Tenant to pay the Additional Rent provided for in this
Article 4 shall survive the expiration of the Lease Term. 

  
 4 

 4.2 Definitions of Key Terms Relating to Additional Rent. As used in this Article
4, the following terms shall have the meanings hereinafter set forth: 
 4.2.1 “Base Year” shall mean calendar year 2011.

 4.2.2 “Direct Expenses” shall mean “Operating Expenses” and “Tax Expenses.” 

4.2.3 “Expense Year” shall mean each calendar year in which any portion of the Lease Term falls, through and including the
calendar year in which the Lease Term expires, provided that Landlord, upon notice to Tenant, may change the Expense Year from time to time to any other twelve (12) consecutive month period, and, in the event of any such change, Tenant’s
Share of Direct Expenses shall be equitably adjusted for any Expense Year involved in any such change. 
 4.2.4 “Operating
Expenses” shall mean all expenses, costs and amounts of every kind and nature which Landlord pays or accrues during any Expense Year because of or in connection with the ownership, management, maintenance, security, repair, replacement,
restoration or operation of the Project, or any portion thereof. Without limiting the generality of the foregoing, Operating Expenses shall specifically include any and all of the following: (i) the cost of supplying all utilities (to the
extent the same is not being paid directly by Tenant), the cost of operating, repairing, maintaining, replacing, renovating and managing the utility, telephone, communications, mechanical, sanitary, storm drainage, and elevator systems, and the cost
of supplies, tools, equipment and maintenance and service contracts in connection therewith; (ii) the cost of licenses, certificates, permits and inspections and the cost of reasonably contesting any governmental enactments which may affect
Operating Expenses, and the costs incurred in connection with a transportation system management program or similar program; (iii) the cost of all insurance carried by Landlord in connection with the Project; (iv) the cost of landscaping,
relamping, and all supplies, tools, equipment and materials used in the operation, repair and maintenance of the Project, or any portion thereof; (v) the costs incurred in connection with the parking areas servicing the Project; (vi) fees
and other costs, including management fees, consulting fees, legal fees and accounting fees, of all contractors and consultants in connection with the management, operation, maintenance and repair of the Project; (vii) payments under any
equipment rental agreements and the fair rental value of any management office space; (viii) wages, salaries and other compensation and benefits, including taxes levied thereon, of all persons engaged in the operation, maintenance and security
of the Project on a full time basis and an appropriate portion of same with respect to persons engaged on a part-time basis; (ix) costs under any instrument pertaining to the sharing of costs by the Project; (x) operation, repair,
maintenance and replacement of all systems and equipment and components thereof of the Building; (xi) the cost of janitorial, alarm, security and other services; (xii) the costs of repair, replacement and restoration of the Common Areas,
including the costs of replacement of wall and floor coverings, ceiling tiles and fixtures, curbs and walkways; (xiii) the costs of repair to roofs and re-roofing; (xiv) amortization (including interest on the unamortized cost) of the cost
of acquiring or the rental expense of personal property used in the maintenance, operation and repair of the Project, or any portion thereof; (xv) the cost of capital improvements or other costs incurred in connection with the Project
(A) which are intended as a labor-saving device or to effect economies in the operation or maintenance of the Project, or any portion thereof, or (B) that are made to the Project after the date of this Lease and that are required under any
governmental law or regulation first enacted, interpreted or applicable to the Project after the Lease Commencement Date; provided, however, that any capital expenditure shall be amortized on a straight-line basis with interest at the “prime
rate” or “reference rate” announced from time to time by Bank of America, N.T. & S.A., (or such reasonable comparable national banking institution as is selected by Landlord in the event Bank of America, N.T. & S.A.,
ceases to publish a prime rate or reference rate), plus two percent (2%), over its useful life as reasonably determined by Landlord using accounting principles consistently applied; (xvi) costs, fees, charges or assessments imposed by, or
resulting from any mandate imposed on Landlord by, any federal, state or local government for fire and police protection, trash removal, community services, or other services which do not constitute “Tax Expenses” as that term is defined
in Section 4.2.5 below; and (xvii) payments under any easement, license, operating agreement, declaration, restrictive covenant, or instrument pertaining to the sharing of costs by the Building. 

If Landlord is not furnishing any particular work or service (the cost of which, if performed by Landlord, would be included in Operating
Expenses) to a tenant who has undertaken to perform such work or service in lieu of the performance thereof by Landlord, Operating Expenses shall be deemed to be increased by an amount equal to the additional Operating Expenses which would
reasonably have been incurred during such period by Landlord if it had at its 

  
 5 

 
own expense furnished such work or service to such tenant. If the Project is not at least one hundred percent (100%) occupied during all or a portion of the Base Year or any Expense Year,
Landlord shall make an appropriate adjustment to the variable cost components of Operating Expenses for such year to determine the amount of Operating Expenses that would have been incurred had the Project been one hundred percent
(100%) occupied; and the amount so determined shall be deemed to have been the amount of Operating Expenses for such year. Operating Expenses for the Base Year shall not include temporary market-wide labor-rate increases due to extraordinary
circumstances, including, but not limited to, boycotts and strikes, and temporary utility rate increases due to extraordinary circumstances including, but not limited to, conservation surcharges, boycotts, embargoes or other shortages. Operating
Expenses for the Base Year shall include amortized costs relating to capital improvements, provided that at such time as any such costs are no longer included in Operating Expenses, such costs shall be excluded from the Base Year calculation of
Operating Expenses. Notwithstanding the foregoing, Operating Expenses shall not, however, include: (A) costs of leasing commissions, attorneys’ fees and other costs and expenses (including advertising and promotional costs) incurred in
connection with negotiations or disputes with present or prospective tenants or other occupants of the Building; (B) costs (including permit, license and inspection costs) incurred in renovating or otherwise improving, decorating or
redecorating rentable space for other tenants or vacant rentable space; (C) costs of overhead or profit increment paid to Landlord or to subsidiaries or affiliates of Landlord for services in or in connection with the Building to the extent the
same exceeds the costs of overhead and profit increment included in the costs of such services which could be obtained from third parties on a competitive basis; (D) except as otherwise specifically provided in this Section 4.2.4, costs of
principal and interest on debt or amortization on any mortgages, and rent payable under any ground lease of the Project; (E) reserves for expenses beyond those for current year anticipated expenses; (F) except as otherwise provided in this
Lease, the cost of any capital improvements; (G) costs associated with the investigation and/or remediation of Hazardous Materials (hereafter defined) present in, on or about the Project, unless such costs and expenses are the responsibility of
Tenant as provided in Article 5 of this Lease, in which event all such costs and expenses shall be paid solely by Tenant in accordance with the provisions of Article 5; (H) Landlord’s general corporate overhead and administrative expenses
except for the property management fee and except as they relate to the specific management of the Project; (I) costs to the extent Landlord is reimbursed directly by other tenants of the Building or through insurance proceeds; and
(J) costs of correcting defects in, or significant design error relating to, the initial design or construction of the Building. 

4.2.5 Taxes. 

4.2.5.1 “Tax Expenses” shall mean all federal, state, county, or local governmental or municipal taxes, fees, charges or
other impositions of every kind and nature, whether general, special, ordinary or extraordinary (including, without limitation, real estate taxes, general and special assessments, transit taxes, leasehold taxes or taxes based upon the receipt of
rent, including gross receipts or sales taxes applicable to the receipt of rent, unless required to be paid by Tenant, personal property taxes imposed upon the fixtures, machinery, equipment, apparatus, systems and equipment, appurtenances,
furniture and other personal property used in connection with the Project, or any portion thereof), which shall be paid or accrued during any Expense Year (without regard to any different fiscal year used by such governmental or municipal authority)
because of or in connection with the ownership, leasing and operation of the Project, or any portion thereof. 
 4.2.5.2 Tax Expenses shall
include, without limitation: (i) Any tax on the rent, right to rent or other income from the Project, or any portion thereof, or as against the business of leasing the Project, or any portion thereof; (ii) Any assessment, tax, fee, levy or
charge in addition to, or in substitution, partially or totally, of any assessment, tax, fee, levy or charge previously included within the definition of real property tax, it being acknowledged by Tenant and Landlord that Proposition 13 was adopted
by the voters of the State of California in the June 1978 election (“Proposition 13”) and that assessments, taxes, fees, levies and charges may be imposed by governmental agencies for such services as fire protection, street,
sidewalk and road maintenance, refuse removal and for other governmental services formerly provided without charge to property owners or occupants, and, in further recognition of the decrease in the level and quality of governmental services and
amenities as a result of Proposition 13, Tax Expenses shall also include any governmental or private assessments or the Project’s contribution towards a governmental or private cost-sharing agreement for the purpose of augmenting or improving
the quality of services and amenities normally provided by governmental agencies; (iii) Any assessment, tax, fee, levy, or charge allocable to or measured by the area of the Premises or the Rent payable hereunder, including, without limitation,
any business or gross receipts or excise tax with respect to the receipt of such rent, or upon or with respect to the possession, leasing, operating, management, 

  
 6 

 
maintenance, alteration, repair, use or occupancy by Tenant of the Premises, or any portion thereof; (iv) Any assessment, tax, fee, levy or charge, upon this transaction or any document to
which Tenant is a party, creating or transferring an interest or an estate in the Premises; and (v) All of the real estate taxes and assessments imposed upon or with respect to the Building and/or the Project. If the Building or the Project is
not fully assessed in the Base Year and any Expense Years, then the Landlord shall adjust the subject year’s Tax Expenses to reflect what such year’s Tax Expenses would have been had the Building/Project been fully completed and assessed
for tax purposes. 
 4.2.5.3 Any reasonable costs and expenses (including, without limitation, reasonable attorneys’ fees) incurred in
attempting to protest, reduce or minimize Tax Expenses shall be included in Tax Expenses in the Expense Year such expenses are paid. Except as set forth in Section 4.2.5.4 below, refunds of Tax Expenses shall be credited against Tax Expenses
and refunded to Tenant regardless of when received, based on the Expense Year to which the refund is applicable, provided that in no event shall the amount to be refunded to Tenant for any such Expense Year exceed the total amount paid by Tenant as
Additional Rent under this Article 4 for such Expense Year. If Tax Expenses for any period during the Lease Term or any extension thereof are increased after payment thereof for any reason, including, without limitation, error or reassessment by
applicable governmental or municipal authorities, Tenant shall pay Landlord, within thirty (30) days following submission to Tenant of an invoice from Landlord, together with reasonable back-up documentation, Tenant’s Share of any such
increased Tax Expenses included by Landlord as Building Tax Expenses pursuant to the terms of this Lease. Notwithstanding anything to the contrary contained in this Section 4.2.5 (except as set forth in Section 4.2.5.1 above), there shall
be excluded from Tax Expenses (i) all excess profits taxes, franchise taxes, gift taxes, capital stock taxes, inheritance and succession taxes, estate taxes, federal and state income taxes, and other taxes to the extent applicable to
Landlord’s general or net income (as opposed to rents, receipts or income attributable to operations at the Project), (ii) any items included as Operating Expenses, and (iii) any items paid by Tenant under Section 4.5 of this
Lease or which would be payable by any other tenant of the Project pursuant to the terms of Section 4.5, irrespective of whether or not such other tenants’ leases contain provisions comparable to Section 4.5 hereof. In no event shall
Tax Expenses include any interest or penalties incurred solely as a result of Landlord’s late payment of Tax Expenses. 
 4.2.5.4
Notwithstanding anything to the contrary set forth in this Lease, the amount of Tax Expenses for the Base Year and any Expense Year shall be calculated without taking into account any decreases in real estate taxes obtained in connection with
Proposition 8, and, therefore, the Tax Expenses in the Base Year and/or an Expense Year may be greater than those actually incurred by Landlord, but shall, nonetheless, be the Tax Expenses due under this Lease; provided that (i) any costs and
expenses incurred by Landlord in securing any Proposition 8 reduction shall not be deducted from Tax Expenses nor included in Direct Expenses for purposes of this Lease, and (ii) tax refunds under Proposition 8 shall not be deducted from Tax
Expenses nor refunded to Tenant, but rather shall be the sole property of Landlord. Landlord and Tenant acknowledge that this Section 4.2.5.4 is not intended to in any way affect (A) the inclusion in Tax Expenses of the statutory two
percent (2.0%) annual increase in Tax Expenses (as such statutory increase may be modified by subsequent legislation), or (B) the inclusion or exclusion of Tax Expenses pursuant to the terms of Proposition 13, which shall be governed
pursuant to the terms of Sections 4.2.5.1 through 4.2.5.3 above. 
 4.2.6 “Tenant’s Share” shall mean the percentage
ratio that the number of rentable square feet in the Premises bears to the number of rentable square feet in the Building. If Tenant’s Share shall be adjusted in accordance with Section 1.2 above at any time after the Base Year, then, as
to the Expense Year in which such change occurs, Tenant’s Share for such Expense Year shall be determined on the basis of the number of days during such Expense Year that each such Tenant’s Share was in effect. 

4.3 Allocation of Direct Expenses. Landlord shall have the right, from time to time, to equitably allocate some or all of the
Direct Expenses for the Project among different portions or occupants of the Project (the “Cost Pools”), in Landlord’s reasonable discretion. Such Cost Pools may include, but shall not be limited to, the office space tenants of
the Project, and the retail space tenants of the Project. The Direct Expenses within each such Cost Pool shall be allocated and charged to the tenants within such Cost Pool in an equitable manner. 

4.4 Calculation and Payment of Additional Rent. If for any Expense Year ending or commencing within the Lease Term,
Tenant’s Share of Direct Expenses for such Expense Year exceeds Tenant’s Share of Direct Expenses applicable to the Base Year, then Tenant shall pay to Landlord, in the manner set forth in Section 4.4.1 below, and as Additional Rent,
an amount equal to the excess (the “Excess”). 

  
 7 

 4.4.1 Statement of Actual Direct Expenses and Payment by Tenant. Landlord shall
promptly deliver to Tenant, and, in any event shall do so within two hundred seventy (270) days following the end of each Expense Year, a statement (the “Statement”) which shall state the Direct Expenses incurred or accrued for
such preceding Expense Year, and which shall indicate the amount of the Excess. Upon receipt of the Statement for each Expense Year commencing or ending during the Lease Term, if an Excess is present, Tenant shall pay, within thirty (30) days,
the full amount of the Excess for such Expense Year, less the amounts, if any, paid during such Expense Year as “Estimated Excess,” as that term is defined in Section 4.4.2 below. If the amounts paid by Tenant during an Expense Year
as Estimated Excess exceed the Excess for such Expense Year, then such difference shall be refunded to Tenant, provided that any refund may, at Landlord’s option, be credited against Additional Rent next coming due under this Lease. The failure
of Landlord to timely furnish the Statement for any Expense Year shall not prejudice Landlord or Tenant from enforcing its rights under this Article 4. Even though the Lease Term has expired and Tenant has vacated the Premises, when the final
determination is made of Tenant’s Share of Direct Expenses for the Expense Year in which this Lease terminates, if an Excess if present, Tenant shall pay to Landlord such amount within thirty (30) days of its receipt of the Statement with
respect thereto. The provisions of this Section 4.4.1 shall survive the expiration or earlier termination of the Lease Term. 
 4.4.2
Statement of Estimated Direct Expenses. In addition, Landlord shall endeavor to give Tenant a yearly expense estimate statement (the “Estimate Statement”) which shall set forth Landlord’s reasonable estimate (the
“Estimate”) of what the total amount of Direct Expenses for the then-current Expense Year shall be and the estimated excess (the “Estimated Excess”) as calculated by comparing the Direct Expenses for such Expense
Year, which shall be based upon the Estimate, to the amount of Direct Expenses for the Base Year. The failure of Landlord to timely furnish the Estimate Statement for any Expense Year shall not preclude Landlord from enforcing its rights to collect
any Estimated Excess under this Article 4, nor shall Landlord be prohibited from revising any Estimate Statement or Estimated Excess theretofore delivered at any time during such Expense Year to take into account variations in the Estimate made by
Landlord. If pursuant to the Estimate Statement an Estimated Excess is calculated for the then-current Expense Year, Tenant shall pay, with its next installment of Base Rent due, a fraction of the Estimated Excess (such amount referred to herein as
the “True-Up Amount”) for the then-current Expense Year (reduced by any amounts paid pursuant to the last sentence of this Section 4.4.2). Such fraction shall have as its numerator the number of months which have elapsed in
such current Expense Year, including the month of such payment, and twelve (12) as its denominator. From and after Tenant’s payment of the True-Up Amount and continuing until a new Estimate Statement is furnished (which Landlord shall have
the right to deliver to Tenant at any time, but not more frequently than two times per any Expense Year), Tenant shall pay monthly, with the monthly Base Rent installments, an amount equal to one-twelfth (1/12) of the total Estimated Excess set
forth in the previous Estimate Statement delivered by Landlord to Tenant pursuant to which the True-Up Amount was calculated. 
 4.5
Taxes and Other Charges for Which Tenant Is Directly Responsible. 
 4.5.1 Tenant shall be liable for and shall pay before
delinquency, taxes levied against Tenant’s equipment, furniture, fixtures and any other personal property located in or about the Premises. If any such taxes on Tenant’s equipment, furniture, fixtures and any other personal property are
levied against Landlord or Landlord’s property or if the assessed value of Landlord’s property is increased by the inclusion therein of a value placed upon such equipment, furniture, fixtures or any other personal property and if Landlord
pays the taxes based upon such increased assessment, which Landlord shall have the right to do regardless of the validity thereof, Tenant shall repay to Landlord, upon demand, the taxes so levied against Landlord or the proportion of such taxes
resulting from such increase in the assessment, as the case may be. 
 4.5.2 If the tenant improvements in the Premises, whether installed
and/or paid for by Landlord or Tenant and whether or not affixed to the real property so as to become a part thereof, are assessed for real property tax purposes at a valuation higher than the valuation at which tenant improvements conforming to
Landlord’s “building standard” in other space in the Building are assessed, then the Tax Expenses levied against Landlord or the property by reason of such excess assessed valuation shall be deemed to be taxes levied against personal
property of Tenant and shall be governed by the provisions of Section 4.5.1 above. 

  
 8 

 4.5.3 Notwithstanding any contrary provision herein, Tenant shall pay prior to delinquency any
(i) rent tax or sales tax, service tax, transfer tax or value added tax, or any other applicable tax on the rent or services herein or otherwise respecting this Lease, (ii) taxes assessed upon or with respect to the possession, leasing,
operation, management, maintenance, alteration, repair, use or occupancy by Tenant of the Premises or any portion of the Project, including the Project parking facility; or (iii) taxes assessed upon this transaction or any document to which
Tenant is a party creating or transferring an interest or an estate in the Premises. 
 4.6 Audit. After delivery to Landlord
of at least thirty (30) days’ prior written notice delivered no later than one hundred twenty (120) days after receipt of a Statement, Tenant, at its sole cost and expense through any accountant designated by it, shall have the right
to examine and/or audit the books and records evidencing such costs and expenses for the previous one (1) calendar year, during Landlord’s reasonable business hours but not more frequently than once during any calendar year. Any such
accounting firm designated by Tenant may not be compensated on a contingency fee basis. Tenant shall have no right to conduct an audit or to give Landlord notice that it desires to conduct an audit at any time an Event of Default exists under the
Lease. The results of any such audit (and any negotiations between the parties related thereto) shall be maintained strictly confidential by Tenant and its accounting firm and shall not be disclosed, published or otherwise disseminated to any other
party other than to Landlord and its authorized agents. Landlord and Tenant each shall use its best efforts to cooperate in such negotiations and to promptly resolve any discrepancies between Landlord and Tenant in the accounting of such costs and
expenses. No subtenant shall have any right to conduct an audit, and no assignee shall conduct an audit for any period during which such assignee was not in possession of the Premises. Tenant’s right to undertake an audit with respect to any
calendar year shall expire one hundred twenty (120) days after Tenant’s receipt of the Statement for such calendar year, and such Statement shall be final and binding upon Tenant and shall, as between the parties, be conclusively deemed
correct, at the end of such one hundred twenty (120) day period, unless Tenant shall have timely given Landlord written notice of its intention to audit Operating Expenses for the calendar year which is the subject of the Statement. If Tenant
timely gives Landlord notice of its intention to audit Operating Expenses, it must commence such audit within thirty (30) days after such notice is delivered to Landlord, and the audit must be completed within ninety (90) days after such
notice is delivered to Landlord (provided, however, that in the event Landlord fails to provide Tenant with access to its books and records within thirty (30) days of Tenant’s notice to Landlord, such thirty (30) and ninety
(90) day periods shall be extended by one day for each day of such delay). If Tenant does not commence and complete the audit within such periods, the Statement which Tenant elected to audit shall be deemed final and binding upon Tenant and
shall, as between the parties, be conclusively deemed correct. If through such audit it is determined that there is a discrepancy of more than five percent (5%) in the amount of Operating Expense payments made by Tenant for such calendar year
when compared to the actual Operating Expenses for such year, then Landlord shall reimburse Tenant for the reasonable accounting costs and expenses incurred by Tenant in performing such audit, including Tenant’s outside auditors or accountants
(but excluding Tenant’s in-house personnel). However, if through such audit it is determined that there is a discrepancy of five percent (5%) or less, then Tenant shall reimburse Landlord for the reasonable accounting costs and expenses
associated with Landlord’s outside accounting firms or auditors (but excluding Landlord’s in-house personnel) in connection with such audit. 

ARTICLE 5 

USE OF PREMISES 

5.1 Permitted Use. Subject to the limitations of Section 5.2 below, Tenant shall use the Premises solely for the Permitted
Use set forth in Section 7 of the Summary and Tenant shall not use or permit the Premises or the Project to be used for any other purpose or purposes whatsoever without the prior written consent of Landlord, which may be withheld in
Landlord’s sole discretion. 
 5.2 Prohibited Uses. The uses prohibited under this Lease shall include, without
limitation, use of the Premises or a portion thereof for (i) offices of any agency or bureau of the United States or any state or political subdivision thereof; (ii) offices or agencies of any foreign governmental or political subdivision
thereof; (iii) offices of any health care professionals or health service organization; (iv) schools or other training facilities which are not 

  
 9 

 
ancillary to corporate, executive or professional office use; (v) retail or restaurant uses; or (vi) broadcast communications firms such as radio and/or television stations. Tenant
shall not allow occupancy density of use of the Premises which is greater than one person per one hundred fifteen (115) rentable square feet of the Premises on average. Tenant further covenants and agrees that Tenant shall not use, or suffer or
permit any person or persons to use, the Premises or any part thereof for any use or purpose contrary to the provisions of the Rules and Regulations set forth in Exhibit D, attached hereto, or in violation of any laws, statutes,
ordinances, regulations or other requirements of the local municipal or county governing body or other lawful authorities having jurisdiction over the Project now in force or which may hereafter be enacted or promulgated (collectively,
“Applicable Laws”) including, without limitation, any such Applicable Laws relating to Hazardous Materials (as hereinafter defined). Tenant shall not do or permit anything to be done in or about the Premises which will in any way
unreasonably obstruct or interfere with the rights of other tenants or occupants of the Building, or use or allow the Premises to be used for any improper, unlawful or objectionable purpose, nor shall Tenant cause, maintain or permit any nuisance
in, on or about the Premises. Tenant shall comply with all recorded covenants, conditions, and restrictions now or hereafter affecting the Project. Landlord covenants that it shall enforce the Rules and Regulations in a non-discriminatory manner.

 5.3 Environmental Covenants. 

5.3.1 As used in this Lease, the term “Hazardous Materials” shall mean and include any substance that is or contains
(1) any “hazardous substance” as now or hereafter defined in § 101(14) of the Comprehensive Environmental Response, Compensation, and Liability Act of 1980, as amended (“CERCLA”) (42 U.S.C. § 9601 et
seq.) or any regulations promulgated under CERCLA; (2) any “hazardous waste” as now or hereafter defined in the Resource Conservation and Recovery Act, as amended (“RCRA”) (42 U.S.C. § 6901 et seq.) or
any regulations promulgated under RCRA; (3) any substance now or hereafter regulated by the Toxic Substances Control Act, as amended (“TSCA”) (15 U.S.C. § 2601 et seq.) or any regulations promulgated under TSCA;
(4) petroleum, petroleum by-products, gasoline, diesel fuel, or other petroleum hydrocarbons; (5) asbestos and asbestos-containing material, in any form, whether friable or non-friable; (6) polychlorinated biphenyls; (7) lead and
lead-containing materials; or (8) any additional substance, material or waste (A) the presence of which on or about the Premises or the Building (i) requires reporting, investigation or remediation under any Environmental Laws (as
hereinafter defined), (ii) causes or threatens to cause a nuisance on the Premises, the Building or any adjacent area or property or poses or threatens to pose a hazard to the health or safety of persons on the Premises, the Building or any
adjacent area or property, or (iii) which, if it emanated or migrated from the Premises or the Building, could constitute a trespass, or (B) which is now or is hereafter classified or considered to be hazardous or toxic under any
Environmental Laws. 
 5.3.2 As used in this Lease, the term “Environmental Laws” shall mean and include (1) CERCLA,
RCRA and TSCA; and (2) any other federal, state or local laws, ordinances, statutes, codes, rules, regulations, orders or decrees now or hereinafter in effect relating to (A) pollution, (B) the protection or regulation of human
health, natural resources or the environment, (C) the treatment, storage or disposal of Hazardous Materials, or (D) the emission, discharge, release or threatened release of Hazardous Materials into the environment. 

5.3.3 Tenant agrees that during its use and occupancy of the Premises that Tenant and its employees, agents, licensees, Transferees (as
defined in Section 14.1 hereof), contractors and invitees (collectively, “Tenant’s Agents”) will (1) neither (A) permit Hazardous Materials to be present on, in or about the Premises, the Building or the Project
except for nominal amounts of normal office supplies used within the Premises in full compliance with Environmental Laws, nor (B) generate, release, discharge, store, dispose of or otherwise handle or use any Hazardous Materials on, in or about
the Premises, the Building or the Project except for nominal amounts of normal office supplies used within the Premises in full compliance with Environmental Laws; (2) comply with all Environmental Laws relating to the Premises, the Building
and/or the Project applicable to Tenant; (3) not engage in or permit any person over whom Tenant has control and/or for which Tenant or any of Tenant’s Agents are legally responsible to engage in any activity at the Premises, the Building
and/or the Project in violation of any Environmental Laws; and (4) notify Landlord of (A) any inquiry, test, investigation or enforcement proceeding by any governmental agency or authority against Tenant, Landlord, the Premises, the
Building or the Project relating to any Hazardous Materials or under any Environmental Laws, or (B) the occurrence of any event or existence of any condition that would cause a breach of any of the covenants set forth in this Section 5.3
promptly upon learning of same. 

  
 10 

 5.3.4 If the use of Hazardous Materials by Tenant or Tenant’s Agents on, in or about the
Premises, the Building or the Project results in a release, discharge or disposal of Hazardous Materials on, in, at, under, or emanating from, the Premises, the Building or the Project, Tenant agrees to investigate, clean up, remove or remediate
such Hazardous Materials in full compliance with (1) the requirements of (A) all Environmental Laws and (B) any governmental agency or authority responsible for the enforcement of any Environmental Laws; and (2) any additional
requirements of Landlord that are reasonably necessary to protect the value of the Premises, the Building and/or the Project. 
 5.3.5 Upon
reasonable prior notice to Tenant, Landlord may enter and inspect the Premises and surrounding areas during regular business hours for the purpose of determining whether there exists on, in or about the Premises any Hazardous Material or other
condition or activity that is in violation of the requirements of this Lease or of any Environmental Laws. In the event (1) such inspections reveal the presence of any such Hazardous Material or other condition or activity in violation of the
requirements of this Lease or of any Environmental Laws, or (2) Tenant or Tenant’s Agents have contributed or consented to the presence of any Hazardous Materials in, on, under, through or about the Premises, the Building and/or the
Project or exacerbated the condition of or the conditions caused by any Hazardous Materials in, on, under, through or about the Premises, the Building and/or the Project, Tenant shall reimburse Landlord for the cost of such inspections within thirty
(30) days of receipt of a written statement therefor, together with reasonable back-up documentation. The right granted to Landlord herein to perform inspections shall not create a duty on Landlord’s part to inspect the Premises, or
liability on the part of Landlord for the use, storage, treatment or disposal of Hazardous Materials by Tenant or Tenant’s Agents, it being understood that Tenant shall be solely responsible for all liability in connection therewith. 

5.3.6 Landlord shall have the right, but not the obligation, prior or subsequent to any Event of Default by Tenant, without in any way
limiting Landlord’s other rights and remedies under this Lease, to enter upon the Premises, or to take such other actions as it deems necessary or advisable, to investigate, clean up, remove or remediate any Hazardous Materials or contamination
by Hazardous Materials present on, in, at, under, or emanating from, the Premises, the Building and/or the Project in violation of Tenant’s obligations under this Lease or Tenant’s obligations under any Environmental Laws. Notwithstanding
any other provision of this Lease, Landlord shall also have the right, at its election, in its own name or as Tenant’s agent, to negotiate, defend, approve and appeal, at Tenant’s sole cost and expense, any action taken or order issued by
any governmental agency or authority with regard to any such Hazardous Materials or contamination by Hazardous Materials. All costs and expenses paid or incurred by Landlord in the exercise of the rights set forth in this Section 5.3 shall be
payable by Tenant upon demand. 
 5.3.7 Tenant agrees to indemnify, defend and hold harmless Landlord from and against any and all claims,
losses, damages, liabilities, costs and expenses of every kind (including, without limitation, loss in value of the Premises, the Building and/or the Project and reasonable attorneys’, experts’ and consultants’ fees and costs)
(collectively, “HazMat Claims”) incurred by Landlord and arising from or in connection with (1) any Hazardous Materials placed on, in or about the Premises, the Building or the Project by Tenant or Tenant’s Agents, or
(2) Tenant’s breach of any provision of this Section 5.3. The provisions of this Section 5.3 shall survive the expiration or earlier termination of this Lease. 

5.3.8 Tenant shall neither be liable for nor otherwise obligated to Landlord under any provision of this Lease with respect to (i) any
HazMat Claim resulting from any Hazardous Materials present in, on or about the Premises, the Building or Project to the extent neither caused nor otherwise permitted, directly or indirectly, by Tenant or Tenant’s Agents; or (ii) the
removal, investigation, monitoring or remediation of any Hazardous Material present in, on or about the Premises, the Building or Project caused by any third party other than Tenant and Tenant’s Agents; provided, however, Tenant shall be fully
liable for and otherwise obligated to Landlord under the provisions of this Lease for all HazMat Claims to the extent (a) Tenant or any of Tenant’s Agents contributes to the presence of such Hazardous Materials or Tenant and/or any of
Tenant’s Agents exacerbates the conditions caused by such Hazardous Materials, or (b) Tenant and/or Tenant’s Agents allows or permits persons over which Tenant or any of Tenant’s Agents has control and/or for which Tenant or any
of Tenant’s Agents are legally responsible for, to cause such Hazardous Materials to be present in, on, under, through or about any portion of the Premises, the Building or Project, or does not take all reasonably appropriate actions to prevent
such persons over which Tenant or any of Tenant’s Agents has control and/or for which Tenant or any of Tenant’s Agents are legally responsible from causing the presence of Hazardous Materials in, on, under, through or about any portion of
the Premises, the Building or Project. 

  
 11 

 ARTICLE 6 

SERVICES AND UTILITIES 

6.1 Standard Tenant Services. Landlord shall provide the following services on all days (unless otherwise stated below) during
the Lease Term. 
 6.1.1 Subject to limitations imposed by all governmental rules, regulations and guidelines applicable thereto, Landlord
shall provide heating and air conditioning (“HVAC”) when necessary for normal comfort for normal office use in the Premises from 8:00 A.M. to 6:00 P.M. Monday through Friday (collectively, the “Building Hours”),
except for the date of observation of New Year’s Day, Memorial Day, Independence Day, President’s Day, Labor Day, Thanksgiving Day, Christmas Day and, at Landlord’s discretion, other locally or nationally recognized holidays
(collectively, the “Holidays”). 
 6.1.2 Landlord shall provide adequate electrical wiring and facilities for connection to
Tenant’s lighting fixtures and incidental use equipment, provided that (i) the connected electrical load of the incidental use equipment (excluding lighting) does not exceed an average of five (5) watts per usable square foot of the
Premises during the Building Hours on a monthly basis, and the electricity so furnished for incidental use equipment will be at a nominal one hundred twenty/two hundred eight (120/208) volts and no electrical circuit for the supply of such
incidental use equipment will require a current capacity exceeding thirty (30) amperes, and (ii) the connected electrical load of Tenant’s lighting fixtures does not exceed an average of one and one-half (1.5) watts per usable
square foot of the Premises during the Building Hours on a monthly basis, and the electricity so furnished for Tenant’s lighting will be at a nominal two hundred seventy-seven (277) volts, all of which electrical usage shall be subject to
applicable laws and regulations, including Title 24 and the availability of such power to the floor on which the Premises is located. Tenant shall bear the cost of replacement of lamps, starters and ballasts for non-Building standard lighting
fixtures within the Premises. 
 6.1.3 Landlord shall provide city water from the existing Building outlets for drinking, lavatory and
toilet purposes in the Building common areas. 
 6.1.4 Landlord shall provide janitorial services to the Premises, Monday through Friday
except the date of observation of the Holidays, in and about the Premises. 
 6.1.5 Landlord shall provide nonexclusive, non-attended
automatic passenger elevator service during the Building Hours and shall have at least one elevator available at all other times. 
 6.1.6
Landlord shall provide nonexclusive freight elevator service subject to scheduling by Landlord. 
 Tenant shall cooperate fully with
Landlord at all times and abide by all regulations and requirements that Landlord may reasonably prescribe for the proper functioning and protection of the HVAC, electrical, mechanical and plumbing systems. 

6.2 Overstandard Tenant Use. Tenant shall not, without Landlord’s prior written consent, which consent shall not be
unreasonably withheld, conditioned or delayed, use (i) heat-generating equipment or machines in the Premises, or (ii) machines, other than normal fractional horsepower office machines, or (iii) lighting in the Premises, which
equipment, machines and/or lighting may affect the temperature otherwise maintained by the air conditioning system or increase the water normally furnished for the Premises by Landlord pursuant to the terms of Section 6.1 of this Lease. If such
consent is given, Landlord shall have the right, following notice to Tenant, to install supplementary facilities and equipment in or servicing the Premises, including supplementary or additional air conditioning and/or metering devices, and the cost
thereof, including the cost of installation, operation and maintenance of any supplementary facilities and/or equipment, increased wear and tear on existing equipment and other similar charges, shall

  
 12 

 
be paid by Tenant to Landlord upon billing by Landlord. If Tenant uses water, electricity, heat or air conditioning in excess of that supplied by Landlord pursuant to Section 6.1 of this
Lease, Tenant shall pay to Landlord, upon billing, the cost of such excess consumption, the cost of the installation, operation, and maintenance of equipment which is installed in order to supply such excess consumption, and the cost of the
increased wear and tear on existing equipment caused by such excess consumption. Tenant’s use of electricity shall never exceed the capacity of the feeders to the Project or the risers or wiring installation. If Tenant desires to use heat,
ventilation or air conditioning during hours other than those for which Landlord is obligated to supply such utilities pursuant to the terms of Section 6.1 of this Lease, Tenant shall give Landlord such prior notice, if any, as Landlord shall
from time to time establish as appropriate, of Tenant’s desired use in order to supply such utilities, and Landlord shall supply such utilities to Tenant at such hourly cost to Tenant (which shall be treated as Additional Rent) as Landlord
shall from time to time establish. The current rate for such services is $115.00 per hour for after-hours heating, ventilating and air conditioning and $35.00 per hour for air circulation only. 

6.3 Interruption of Use. Tenant agrees that, except as otherwise expressly provided herein, Landlord shall not be liable for
damages, by abatement of Rent or otherwise, for failure to furnish or delay in furnishing any service (including telephone and telecommunication services), or for any diminution in the quality or quantity thereof, when such failure or delay or
diminution is occasioned, in whole or in part, by breakage, repairs, replacements, or improvements, by any strike, lockout or other labor trouble, by inability to secure electricity, gas, water, or other fuel at the Building or Project after
reasonable effort to do so, by any riot or other dangerous condition, emergency, accident or casualty whatsoever, by act or default of Tenant or other parties, or by any other cause; and such failures or delays or diminution shall never be deemed to
constitute an eviction or disturbance of Tenant’s use and possession of the Premises or relieve Tenant from paying Rent or performing any of its obligations under this Lease. Furthermore, Landlord shall not be liable under any circumstances for
a loss of, or injury to, property or for injury to, or interference with, Tenant’s business, including, without limitation, loss of profits, however occurring, through or in connection with or incidental to a failure to furnish any of the
services or utilities as set forth in this Article 6. Landlord may comply with voluntary controls or guidelines promulgated by any governmental entity relating to the use or conservation of energy, water, gas, light or electricity or the reduction
of automobile or other emissions without creating any liability of Landlord to Tenant under this Lease, provided that the Premises are not thereby rendered untenantable. Notwithstanding any provision contained herein to the contrary, Tenant’s
Base Rent shall be abated to the extent that utility services are interrupted for a period of five (5) or more consecutive business days as a result of Landlord’s or its authorized representatives’ gross negligence or willful
misconduct; provided Tenant is prevented from using the Premises as a result thereof. 
 6.4 Server Room. Landlord and Tenant
acknowledge that a portion of the Premises shall be used as a server room (the “Server Room”) which may require electricity and HVAC services twenty-four (24) hours per day, three hundred sixty-five (365) days per year.
Landlord agrees that, subject to the terms of this Lease, Landlord shall provide Tenant and the Server Room with such services, at Tenant’s sole cost and expense. Tenant shall install, at Tenant’s sole cost and expense, HVAC to the Server
Room and a separate monitoring device to measure such Server Room usage and Tenant shall pay for the actual costs of such services (without mark-up by Landlord) within thirty (30) days following Landlord’s delivery to Tenant of an invoice
therefor, together with reasonable back-up documentation. 
 ARTICLE 7 

REPAIRS 
 7.1
Tenant’s Repairs. Tenant shall, at Tenant’s own expense, pursuant to the terms of this Lease, including without limitation Article 8 hereof, keep the Premises, including all improvements, fixtures and furnishings therein and
all heating, ventilating, air conditioning, electrical and utility systems that are located within or exclusively serve the Premises, in good order, repair and condition at all times during the Lease Term. In addition, Tenant shall, at Tenant’s
own expense, but under the supervision and subject to the prior approval of Landlord, which shall not be unreasonably withheld, conditioned or delayed, and within any reasonable period of time specified by Landlord, pursuant to the terms of this
Lease, including without limitation Article 8 hereof, promptly and adequately repair all damage to the Premises and replace or repair all damaged, broken, or worn fixtures and appurtenances, except for damage caused by casualty to, or condemnation
of, the Premises, and ordinary wear and tear; provided however, that Landlord shall have the exclusive right, exercisable at Landlord’s option, but not the obligation, upon reasonable prior notice to Tenant, to make such repairs and
replacements in the event Tenant fails to timely do so, and Tenant shall pay to Landlord the reasonable cost 

  
 13 

 
thereof, including a percentage of the cost thereof sufficient to reimburse Landlord for all overhead, general conditions, fees and other costs or expenses arising from Landlord’s
involvement with such repairs and replacements within thirty (30) days following Landlord’s delivery to Tenant of an invoice therefor, together with reasonable back-up documentation. Landlord may, but shall not be required to, enter the
Premises at all reasonable times upon reasonable prior notice to Tenant (which may be oral and which shall not be required in cases of emergency) to make such repairs, alterations, improvements or additions to the Premises or to the Project or to
any equipment located in the Project as Landlord shall desire or deem necessary or as Landlord may be required to do by governmental or quasi-governmental authority or court order or decree. Tenant hereby waives any and all rights under and benefits
of subsection 1 of Section 1932 and Sections 1941 and 1942 of the California Civil Code or under any similar law, statute, or ordinance now or hereafter in effect. 

7.2 Landlord’s Repairs. Subject to the provisions of the immediately preceding paragraph, Articles 11 and 13 of this Lease
and Tenant’s obligations under Article 4 to reimburse Landlord for Tenant’s Share of Direct Expenses, Landlord shall maintain or cause to be maintained in good order, condition and repair, the structural portions of the roof, foundations,
floors and exterior walls of the Building (including all exterior windows) and the Building plumbing, heating, ventilating, air conditioning and electrical systems serving the Building and the Common Areas; provided, however, that Tenant shall pay
the cost of repairs or replacements arising out of the negligence or willful misconduct of Tenant or Tenant’s Agents. Landlord shall be under no obligation to inspect the Premises. Tenant shall promptly report in writing to Landlord any
defective condition known to it which Landlord is required to repair. 
 ARTICLE 8 

ADDITIONS AND ALTERATIONS 

8.1 Landlord’s Consent to Alterations. Tenant may not make any improvements, alterations, additions or changes
(individually, an “Alteration”; collectively, the “Alterations”) to the Premises or to any mechanical, plumbing or HVAC facilities or systems pertaining to the Premises without first procuring the prior written
consent of Landlord to such Alterations, which consent shall be requested by Tenant not less than thirty (30) days prior to the commencement thereof, and which consent shall not be unreasonably withheld, conditioned or delayed by Landlord,
provided it shall be deemed reasonable for Landlord to withhold its consent to any Alteration which adversely affects the structural portions or the systems or equipment of the Building or is visible from the exterior of the Building. The
construction of the initial improvements to the Premises shall be governed by the terms of the Tenant Work Letter and not the terms of this Article 8. Notwithstanding the foregoing to the contrary, Tenant may, at its sole cost and expense and
without Landlord’s written consent, perform interior, non-structural alterations or additions to the Premises provided such alterations or additions do not affect the structural components of the Building or Systems and Equipment or require any
permit or roof penetrations and the cost of which does not exceed $50,000 in the aggregate over a 12 month period (the “Permitted Alterations”). Tenant shall first notify Landlord at least fifteen (15) days prior to commencing any
Permitted Alterations so that Landlord may post a Notice of Non-Responsibility on the Premises. 
 8.2 Manner of Construction.
Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the
requirement that Tenant utilize for such purposes only contractors, subcontractors, materials, mechanics and materialmen selected by Tenant from a list provided and approved by Landlord. Notwithstanding the foregoing, with respect to construction of
the initial Tenant Improvements as described on Exhibit B attached hereto, Landlord hereby approves TCB Builders, Inc. as Tenant’s contractor and further approves all architects, engineers, project managers, subcontractors,
mechanics and materialmen and other consultants selected by TCB Builders, Inc. (the “TCB Subcontractors”) provided each such TCB Subcontractor utilizes union labor and is a reputable, licensed company doing business in San
Francisco, California. Tenant shall provide Landlord with a list of all TCB Subcontractors prior to commencement of any construction in the Premises. Notwithstanding anything to the contrary contained herein, in the event that Tenant desires access
to the Building risers in connection with the exercise of its rights pursuant to this paragraph, then Tenant shall be required to utilize the services of Landlord’s designated Building riser management company. The contractor or person selected
by Tenant or Landlord to make Alterations must declare to Landlord in writing that he or she belongs to a local trade union, and must be approved in writing by Landlord prior to commencement of any work. If a subcontractor is selected to perform the
work, the general contractor must 

  
 14 

 
warrant and represent to Landlord in writing that such subcontractor belongs to a local trade union. If such Alterations will involve the use of or disturb Hazardous Materials existing in the
Premises, Tenant shall comply with Landlord’s rules and regulations concerning such Hazardous Materials. Tenant shall construct such Alterations and perform such repairs in a good and workmanlike manner, in conformance with any and all
Applicable Laws, pursuant to a valid building permit, issued by the City of San Francisco, and in conformance with Landlord’s reasonable construction rules and regulations. In the event Tenant performs any Alterations in the Premises which
require or give rise to governmentally required changes to the “Base Building,” as that term is defined below, then Landlord shall, at Tenant’s expense, make such changes to the Base Building. The “Base Building”
shall include the structural portions of the Building, and the public restrooms and the systems and equipment located in the internal core of the Building on the floor or floors on which the Premises are located. In performing the work of any such
Alterations, Tenant shall have the work performed in such manner so as not to obstruct access to the Project or any portion thereof, for any other tenant of the Project, and so as not to obstruct the business of Landlord or other tenants in the
Project. Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with the workforce or trades
engaged in performing other work, labor or services in or about the Building or the Common Areas. In addition to Tenant’s obligations under Article 9 of this Lease, upon completion of any Alterations, Tenant agrees to cause a Notice of
Completion to be recorded in the office of the Recorder of the County of San Francisco in accordance with Section 3093 of the Civil Code of the State of California or any successor statute, and Tenant shall deliver to the Project management
office a reproducible copy of the “as built” drawings of the Alterations as well as all permits, approvals and other documents issued by any governmental agency in connection with the Alterations. 

8.3 Payment for Improvements. If payment is made directly to contractors, Tenant shall comply with Landlord’s reasonable
requirements for final lien releases and waivers in connection with Tenant’s payment for work to contractors. If Tenant requests any alteration, repair or improvement work to be performed by Landlord, Tenant shall pay to Landlord a percentage
not to exceed seven percent (7%) if the total cost of such work is equal to or less than Ten Thousand Dollars ($10,000) and, if the total cost exceeds Ten Thousand Dollars ($10,000), then such percentage shall not exceed five percent
(5%) of the cost of such work sufficient to compensate Landlord for all overhead, general conditions, fees and other costs and expenses arising from Landlord’s involvement with such work. If Tenant does not request Landlord to perform any
such work, Tenant shall reimburse Landlord for Landlord’s reasonable, actual, out-of-pocket costs and expenses actually incurred in connection with Landlord’s review of such work within thirty (30) days of Landlord’s submission
to Tenant of an invoice therefor, together with reasonable back-up documentation. 
 8.4 Construction Insurance. In addition
to the requirements of Article 10 of this Lease, in the event that Tenant makes any Alterations, prior to the commencement of such Alterations, Tenant shall provide Landlord with evidence that Tenant or Tenant’s contractor carries
“Builder’s All Risk” insurance in an amount reasonably approved by Landlord covering the construction of such Alterations, and such other insurance as Landlord may reasonably require, it being understood and agreed that all of such
Alterations shall be insured by Tenant pursuant to Article 10 of this Lease immediately upon completion thereof. In addition, for Alterations the estimated cost of which exceeds $50,000, Landlord may, in its discretion, require Tenant to obtain a
lien and completion bond or some alternate form of security satisfactory to Landlord in an amount sufficient to ensure the lien-free completion of such Alterations and naming Landlord as a co-obligee. Notwithstanding the foregoing, so long as Tenant
is the entity initially named in this Lease, then the lien and completion bond that may be required pursuant to the immediately preceding sentence shall only be required, if at all, in the event Tenant’s Alterations are estimated to cost in
excess of $200,000. No lien or completion bond shall be required in connection with construction of the Tenant Improvements pursuant to Exhibit B. 

8.5 Landlord’s Property. All Alterations, improvements, fixtures, equipment and/or appurtenances which may be installed or
placed in or about the Premises, from time to time, shall be at the sole cost of Tenant and, except for Tenant’s Property (as defined in Section 15.2), shall be and become the property of Landlord. Furthermore, Landlord may, by written
notice to Tenant at the time Landlord consents to any Alteration, require Tenant, at Tenant’s expense, to (i) remove any Alterations in the Premises, and/or (ii) remove any “Non Standard Tenant Improvements,” as that term is
defined in Section 2.4 of the Tenant Work Letter, located within the Premises and replace the same with then existing “Building Standard Tenant Improvements,” as that term is defined in Section 2.3 of the Tenant Work Letter, and
to repair any damage to the Premises and Building caused by such removal and return the affected portion of the Premises to a building standard tenant improved condition as reasonably determined by Landlord; provided, however, that in no event

  
 15 

 
shall Tenant be required to remove any of the Tenant Improvements (other than telephone, data and other cabling and wiring and other than as set forth in Section 15.2 below). If Tenant fails
to complete such removal and/or to repair any damage caused by the removal of any Alterations in the Premises, and/or fails to return the affected portion of the Premises to a building standard tenant improved condition as reasonably determined by
Landlord, then at Landlord’s option, either (A) Tenant shall be deemed to be holding over in the Premises and Rent shall continue to accrue in accordance with the terms of Article 16 below, until such work shall be completed, or
(B) Landlord may do so and may charge the cost thereof to Tenant. Tenant hereby agrees to protect, defend, indemnify and hold Landlord harmless from any liability, cost, damages, obligation, expense or claim (including reasonable
attorneys’ fees) in any manner relating to the installation, placement, removal or financing of any such Alterations, improvements, fixtures and/or equipment placed or installed in, on or about the Premises by or on behalf of Tenant, which
obligations of Tenant shall survive the expiration or earlier termination of this Lease. 
 8.6 Wi-Fi Network. Without
limiting the generality of the foregoing, Tenant shall be permitted to install wireless intranet, Internet and communications network (“Wi-Fi Network”) in the Premises for the use by Tenant and its employees, and, to the extent
permitted by Applicable Laws, the same shall be subject to the provisions of this Section 8.6 (in addition to the other provisions of this Article 8). Tenant shall, in accordance with Section 15.2 below, remove the Wi-Fi Network from the
Premises prior to the termination of the Lease. Tenant shall use the Wi-Fi Network so as not to cause any interference to other tenants in the Building or Project or with any other tenant’s communication equipment, and not to damage the
Building or Project or interfere with the normal operation of the Building or Project and Tenant hereby agrees to indemnify, defend and hold Landlord harmless from and against any and all claims, costs, damages, expenses and liabilities (including
reasonable attorneys’ fees) arising out of Tenant’s failure to comply with the provisions of this Section 8.6, except to the extent same is caused by the gross negligence or willful misconduct of Landlord and which is not covered by
the insurance carried by Tenant under this Lease (or which would not be covered by the insurance required to be carried by Tenant under this Lease). Should any interference occur, Tenant shall take all necessary steps as soon as reasonably possible
and no later than three (3) business days following such occurrence to correct such interference. If such interference continues after such three (3) business day period, Tenant shall immediately cease operating such Wi-Fi Network until
such interference is corrected or remedied to Landlord’s satisfaction. Tenant acknowledges that Landlord has granted and/or may grant telecommunication rights to other tenants and occupants of the Building and to telecommunication service
providers and in no event shall Landlord be liable to Tenant for any interference of the same with such Wi-Fi Network. Landlord makes no representation that the Wi-Fi Network will be able to receive or transmit communication signals without
interference or disturbance. Tenant shall (i) be solely responsible for any damage caused as a result of the Wi-Fi Network, (ii) promptly pay any tax, license or permit fees charged pursuant to any laws or regulations in connection with
the installation, maintenance or use of the Wi-Fi Network and comply with all precautions and safeguards recommended by all governmental authorities, and (iii) pay for all necessary repairs, replacements to or maintenance of the Wi-Fi Network.
Should Landlord be required to retain professionals to research any interference issues that may arise and to confirm Tenant’s compliance with the terms of this Section 8.6, Landlord shall retain such professionals at commercially
reasonable rates, and Tenant shall reimburse Landlord within thirty (30) days following submission to Tenant of an invoice from Landlord, together with reasonable back-up documentation, which costs shall not exceed $1,000 per year (except in
the event of an Event of Default by Tenant hereunder). This reimbursement obligation is independent of any rights or remedies Landlord may have in the event of a breach or default by Tenant under this Lease. 

ARTICLE 9 

COVENANT AGAINST LIENS 

Tenant shall keep the Project and Premises free from any liens or encumbrances arising out of the work performed, materials furnished or
obligations incurred by or on behalf of Tenant, and shall protect, defend, indemnify and hold Landlord harmless from and against any claims, liabilities, judgments, expenses or costs (including, without limitation, reasonable attorneys’ fees
and costs) arising out of same or in connection therewith. Tenant shall give Landlord notice at least twenty (20) days prior to the commencement of any such work on the Premises (or such additional time as may be necessary under Applicable
Laws) to afford Landlord the opportunity of posting and recording appropriate notices of non-responsibility. Tenant shall remove any such lien or encumbrance by bond or otherwise within ten (10) days after notice by Landlord, and if Tenant
shall fail to do so, Landlord may pay the amount necessary to 

  
 16 

 
remove such lien or encumbrance, without being responsible for investigating the validity thereof. The amount so paid shall be deemed Additional Rent under this Lease payable upon demand, without
limitation as to other remedies available to Landlord under this Lease. Nothing contained in this Lease shall authorize Tenant to do any act which shall subject Landlord’s title to the Building or Premises to any liens or encumbrances whether
claimed by operation of law or express or implied contract. Any claim to a lien or encumbrance upon the Building or Premises arising in connection with any such work or respecting the Premises not performed by or at the request of Landlord shall be
null and void, or at Landlord’s option shall attach only against Tenant’s interest in the Premises and shall in all respects be subordinate to Landlord’s title to the Project, Building and Premises. 

ARTICLE 10 

INSURANCE 
 10.1
Indemnification and Waiver. Except to the extent caused by Landlord’s gross negligence or willful misconduct, Tenant hereby assumes all risk of damage to property or injury to persons in, upon or about the Premises, the Building
and/or the Project, from any cause whatsoever (including, without limitation, personal injuries occurring in, on, upon or about the Premises, the Building and/or the Project) and agrees that Landlord, its partners, representatives, members, agents,
employees, directors, officers, successors and assign (collectively, “Landlord Parties”) shall not be liable for, and are hereby released from any responsibility for, any damage either to person or property or resulting from the
loss of use thereof, which damage is sustained by Tenant or by other persons claiming through Tenant from any cause whatsoever. Tenant shall indemnify, defend, protect, and hold harmless the Landlord Parties from any and all losses, costs, damages,
claims, judgments, expenses and liability (including without limitation court costs and reasonable attorneys’ fees) (individually, a “Claim”; collectively, “Claims”) incurred in connection with or arising from
any cause in, on or about the Premises, the Building and/or the Project, including, without limiting the generality of the foregoing: (i) any violation by Tenant or Tenant’s Agents of any Applicable Laws, including, without limitation, any
Environmental Laws, (ii) the use or occupancy or manner of use or occupancy of the Premises, the Building and/or the Project by Tenant or Tenant’s Agents or any person or entity claiming through or under Tenant, (iii) the passive
negligence or active negligence, to the extent active negligence is not deemed to be gross negligence, of Landlord, (iv) any acts, omissions or negligence of Tenant or of any person claiming by, through or under Tenant, or of Tenant’s
Agents or any such person, in, on or about the Project or (v) any default by Tenant or Tenant’s Agents in the observance or performance of any of the terms, covenants or conditions of this Lease, either prior to, during, or after the
expiration of the Lease Term, provided that the terms of the foregoing indemnity shall not apply to any Claims arising from the gross negligence or willful misconduct of Landlord or any other Landlord Parties. In the event any action or proceeding
is brought against Landlord for any Claim against which Tenant is obligated to indemnify Landlord hereunder, Tenant upon notice from Landlord shall defend such action or proceeding at Tenant’s sole expense by counsel selected by Landlord. The
provisions of this Section 10.1 shall survive the expiration or sooner termination of this Lease. Notwithstanding the provisions of this Section 10.1 above to the contrary, Tenant’s indemnity of Landlord and the Landlord Parties shall
not apply to: (i) any claims to the extent resulting from the gross negligence or willful misconduct of the Landlord Parties and not insured or required to be insured by Tenant under this Lease (collectively, the “Excluded
Claims”); or (ii) any loss of or damage to Landlord’s property to the extent Landlord has waived such loss or damage pursuant to Section 10.5 below. In addition, Landlord shall indemnify, defend, protect and hold Tenant
harmless from all such Excluded Claims, except for (A) any loss or damage to Tenant’s property to the extent Tenant has waived such loss or damage pursuant to Section 10.5 below, and (B) any lost profits, loss of business or
other consequential damages. 
 10.2 Tenant’s Compliance With Landlord’s Fire and Casualty Insurance. Tenant shall,
at Tenant’s expense, comply with all insurance company requirements pertaining to the use of the Premises. Tenant shall not cause or permit anything to be done in, upon or about the Premises which would in any way increase the premium for,
cause the cancellation of or otherwise affect any insurance carried by Landlord in connection with the Project. Without limiting Landlord’s remedies for Tenant’s breach of the foregoing covenant, if Tenant’s conduct or use of the
Premises causes any increase in the premium for such insurance policies, then Tenant shall reimburse Landlord for any such increase promptly upon being billed therefor. Tenant, at Tenant’s sole cost and expense, shall comply with all rules,
orders, regulations or requirements of the American Insurance Association (formerly the National Board of Fire Underwriters) and any similar body. 

  
 17 

 10.3 Tenant’s Insurance. Throughout the Term of the Lease, Tenant shall
maintain the following coverages in the following amounts. 
 10.3.1 Commercial General Liability Insurance covering the insured against
claims of bodily injury, personal injury and property damage (including loss of use thereof) arising out of Tenant’s operations, and contractual liabilities (covering the performance by Tenant of its indemnity agreements) and covering the
insuring provisions of this Lease and the performance by Tenant of the indemnity agreements set forth in Section 10.1 of this Lease, for limits of liability not less than: 

 

			
	 Bodily Injury and
	  	$1,000,000 each occurrence
	 Property Damage Liability
	  	$2,000,000 annual aggregate
		
	 Personal Injury Liability
	  	$1,000,000 each occurrence
		  	$2,000,000 annual aggregate
		
	 Excess/Umbrella Coverage
	  	$10,000,000
0% Insured’s participation

 10.3.2 Physical Damage Insurance covering (i) all office furniture, business and trade fixtures, office
equipment, free-standing cabinet work, movable partitions, merchandise and all other items of Tenant’s property on the Premises installed by, for, or at the expense of Tenant, (ii) the “Tenant Improvements,” as that term is
defined in Section 2.1 of the Tenant Work Letter, and any other improvements which exist in the Premises as of the Lease Commencement Date (excluding the Base Building) (the “Original Improvements”), and (iii) all other
Alterations to the Premises. Such insurance shall be written on an “all risks” of physical loss or damage basis, subject to policy terms, conditions and exclusions and excluding Flood and Earthquake coverages, for 100% of the full
replacement cost new, without deduction for depreciation of the covered items, with deductible amounts not to exceed Ten Thousand Dollars ($10,000) and in amounts that meet any co-insurance clauses of the policies of insurance and shall include
coverage for damage or other loss caused by fire or other peril including, but not limited to, vandalism and malicious mischief, theft, water damage of any type, including sprinkler leakage, bursting or stoppage of pipes, and explosion, and
providing business interruption coverage for a period of one year. 
 10.3.3 Worker’s Compensation Insurance in accordance with
statutory law and Employer’s Liability Insurance with a limit of not less than $1,000,000 per accident, $1,000,000 disease policy limit and $1,000,000 disease limit each employee. 

10.3.4 Loss-of-income, business interruption and extra-expense insurance, in such amounts as will reimburse Tenant for direct or indirect loss
of earnings for a period of twelve (12) months and attributable to all perils commonly insured against by prudent tenants or attributable to prevention of access to the Premises or to the Building as a result of such perils. 

10.3.5 Comprehensive Automobile Liability Insurance having a combined single limit of not less than One Million Dollars ($1,000,000) per
occurrence and insuring Tenant against liability for claims arising out of ownership, maintenance or use of any owned, hired or non-owned automobiles. 

10.4 Form of Policies. The minimum limits of policies of insurance required of Tenant under this Lease shall in no event limit
the liability of Tenant under this Lease. The General Liability insurance policy shall (i) name Landlord, Landlord’s lender, and any other party the Landlord so specifies, as an additional insured, including Landlord’s managing agent,
if any; (ii) specifically cover the liability assumed by Tenant under this Lease, including, but not limited to, Tenant’s obligations under Section 10.1 of this Lease; (iii) be issued by an insurance company having a rating of
not less than A-:IX in Best’s Insurance Guide or which is otherwise reasonably acceptable to Landlord and licensed to do business in the State of California; (iv) be primary insurance as to all claims thereunder and provide that any
insurance carried by Landlord is excess and is non-contributing with any insurance requirement of Tenant; (v) be in form and content reasonably acceptable to Landlord; and (vi) provide that said insurance shall not be canceled or coverage

  
 18 

 
changed unless thirty (30) days’ prior written notice shall have been given to Landlord and any mortgagee of Landlord. Tenant shall deliver said policy or policies or certificates
thereof to Landlord on or before the Lease Commencement Date and, thereafter, at least thirty (30) days before the expiration dates thereof. In the event Tenant shall fail to procure such insurance, or to deliver such policies or certificate,
Landlord may, at its option, procure such policies for the account of Tenant, and the cost thereof shall be paid to Landlord within five (5) days after delivery to Tenant of bills therefor. At Tenant’s option, Tenant may provide the
coverages required under this Article 10 through blanket policies of insurance covering Tenant’s other properties, so long as the coverage required under this Lease with respect to the Premises, Building and Project is not reduced or impaired
as a result thereof (including as a result of any claims made or aggregate limits with respect to such other properties) including deductibles, retentions or self-insurance applicable thereto. 

10.5 Subrogation. Landlord and Tenant intend that their respective property loss risks shall be borne by reasonable insurance
carriers to the extent above provided, and Landlord and Tenant hereby agree to look solely to, and seek recovery only from, their respective insurance carriers in the event of a property loss to the extent that such coverage is agreed to be provided
hereunder. The parties each hereby waive all rights and claims against each other for such losses, and waive all rights of subrogation of their respective insurers, provided such waiver of subrogation shall not affect the right to the insured to
recover thereunder. The parties agree that their respective insurance policies are now, or shall be, endorsed such that the waiver of subrogation shall not affect the right of the insured to recover thereunder. 

10.6 Additional Insurance Obligations. Tenant shall carry and maintain during the entire Lease Term, at Tenant’s sole cost
and expense, increased amounts of the insurance required to be carried by Tenant pursuant to this Article 10 and such other reasonable types of insurance coverage and in such reasonable amounts covering the Premises and Tenant’s operations
therein, as may be reasonably requested by Landlord. 
 ARTICLE 11 

DAMAGE AND DESTRUCTION 

11.1 Repair of Damage to Premises by Landlord. Tenant shall promptly notify Landlord of any damage to the Premises resulting
from fire or any other casualty. If the Premises or any Common Areas necessary to Tenant’s use or access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for
insurance adjustment or other matters beyond Landlord’s reasonable control, and subject to all other terms of this Article 11, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the
Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other Applicable Laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common
Areas deemed desirable by Landlord. Following the occurrence of any damage to the Premises, Landlord may elect by written notice (the “Landlord Repair Notice”) to Tenant to repair such damage and restore the Tenant Improvements and
Original Improvements, in which case Tenant shall assign to Landlord (or to any party designated by Landlord) all insurance proceeds payable to Tenant under Tenant’s insurance required under items (ii) and (iii) of Section 10.3.2
of this Lease, and thereafter Landlord shall repair any injury or damage to the Tenant Improvements and the Original Improvements installed in the Premises and shall return such Tenant Improvements and Original Improvements to their original
condition; provided that if the cost of such repair by Landlord exceeds the amount of insurance proceeds received by Landlord from Tenant’s insurance carrier, as assigned by Tenant in accordance with the foregoing, the cost of such repairs
shall be paid by Tenant to Landlord prior to Landlord’s commencement of repair of the damage. In the event that Landlord does not deliver a Landlord Repair Notice within sixty (60) days following the date the casualty becomes known to
Landlord, Tenant shall, at its sole cost and expense, repair any injury or damage to the Tenant Improvements and the Original Improvements installed in the Premises and shall return such Tenant Improvements and Original Improvements to their
original condition. Whether or not Landlord delivers a Landlord Repair Notice, prior to the commencement of construction, Tenant shall submit to Landlord, for Landlord’s review and approval, all plans, specifications and working drawings
relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant’s business resulting in any way from
such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or a portion thereof or the Common Areas necessary to Tenant’s occupancy, Landlord shall allow Tenant a proportionate
abatement of Rent to the extent Landlord is reimbursed from the proceeds of rental interruption insurance purchased by 

  
 19 

 
Landlord as part of Operating Expenses, during the time and to the extent and in the proportion that the Premises or such portion thereof are unfit for occupancy for the purposes permitted under
this Lease, and not occupied by Tenant as a result thereof; provided, further, however, that if the damage or destruction is due to the negligence or willful misconduct of Tenant or any of Tenant’s Agents, Tenant shall be responsible for any
reasonable, applicable insurance deductible (which shall be payable to Landlord upon demand) and there shall be no rent abatement. In the event that Landlord shall not deliver the Landlord Repair Notice, Tenant’s right to rent abatement
pursuant to the preceding sentence shall terminate as of the date which is reasonably determined by Landlord to be the date Tenant should have completed repairs to the Premises assuming Tenant used reasonable due diligence in connection therewith.

 11.2 Landlord’s Option to Repair. Notwithstanding the terms of Section 11.1 of this Lease, Landlord may elect not
to rebuild and/or restore the Premises, Building and/or Project, and instead terminate this Lease, by notifying Tenant in writing of such termination within sixty (60) days after the date of discovery of the damage, such notice to include a
termination date giving Tenant sixty (60) days to vacate the Premises, but Landlord may so elect only if the Building or Project shall be damaged by fire or other casualty or cause, whether or not the Premises are affected, and one or more of
the following conditions is present: (i) in Landlord’s reasonable judgment, repairs cannot reasonably be completed within one hundred eighty (180) days after the date of discovery of the damage (when such repairs are made without the
payment of overtime or other premiums); (ii) the holder of any mortgage on the Building or Project or ground lessor with respect to the Building or Project shall require that the insurance proceeds or any portion thereof be used to retire the
mortgage debt, or shall terminate the ground lease, as the case may be; (iii) the damage is not fully covered by Landlord’s insurance policies; (iv) Landlord decides to rebuild the Building or Common Areas so that they will be
substantially different structurally or architecturally; or (v) the damage occurs during the last twelve (12) months of the Lease Term. In the event this Lease is terminated in accordance with the terms of this Section 11.2, then
Tenant shall assign to Landlord (or to any party designated by Landlord) all insurance proceeds payable to Tenant under Tenant’s insurance required under items (ii) and (iii) of Section 10.3.2 of this Lease. 

11.3 Tenant’s Termination Option. If (i) Landlord does not elect to terminate this Lease pursuant to Landlord’s
termination right as provided in Section 11.2 above, (ii) the damage is not the result of Tenant’s negligence or willful misconduct, (iii) the damage materially interferes with Tenant’s access to or usage of the Premises and
Tenant does not thereafter use the Premises, and (iv) Landlord’s restoration work cannot, in the reasonable opinion of Landlord’s licensed contractor, be substantially completed within one hundred eighty (180) days after the date
of damage, then Tenant may elect to terminate this Lease by delivering written notice thereof to Landlord within thirty (30) days after Tenant’s receipt of Landlord’s notice of the damage, which termination shall be effective as of
the date which is thirty (30) days after the date such termination notice is delivered to Landlord. Furthermore, in the event Landlord’s restoration work has not been substantially completed within one hundred eighty (180) days after
the date of damage and the then condition of the Premises or the Building materially interferes with Tenant’s access to or usage of the Premises, then Tenant may elect to terminate this Lease by delivering written notice thereof to Landlord at
any time prior to the substantial completion of such restoration work, which termination shall be effective as of the date which is thirty (30) days after the date such termination notice is delivered to Landlord unless, within such thirty
(30) day period, the restoration work has been substantially completed. 
 11.4 Waiver of Statutory Provisions. The
provisions of this Lease, including this Article 11, constitute an express agreement between Landlord and Tenant with respect to any and all damage to, or destruction of, all or any part of the Premises, the Building or the Project, and any statute
or regulation of the State of California, including, without limitation, Sections 1932(2), 1933(4), 1941 and 1942 of the California Civil Code, with respect to any rights or obligations concerning damage or destruction in the absence of an express
agreement between the parties, and any other statute or regulation, now or hereafter in effect, shall have no application to this Lease or any damage or destruction to all or any part of the Premises, the Building or the Project. 

ARTICLE 12 

NONWAIVER 
 No
provision of this Lease shall be deemed waived by either party hereto unless expressly waived in a writing signed thereby. The waiver by either party hereto of any breach of any term, covenant or condition herein contained

  
 20 

 
shall not be deemed to be a waiver of any subsequent breach of same or any other term, covenant or condition herein contained. The subsequent acceptance of Rent hereunder by Landlord shall not be
deemed to be a waiver of any preceding breach by Tenant of any term, covenant or condition of this Lease, other than the failure of Tenant to pay the particular Rent so accepted, regardless of Landlord’s knowledge of such preceding breach at
the time of acceptance of such Rent. No acceptance of a lesser amount than the Rent herein stipulated shall be deemed a waiver of Landlord’s right to receive the full amount due, nor shall any endorsement or statement on any check or payment or
any letter accompanying such check or payment be deemed an accord and satisfaction, and Landlord may accept such check or payment without prejudice to Landlord’s right to recover the full amount due. No receipt of monies by Landlord from Tenant
after the termination of this Lease shall in any way alter the length of the Lease Term or of Tenant’s right of possession hereunder, or after the giving of any notice shall reinstate, continue or extend the Lease Term or affect any notice
given Tenant prior to the receipt of such monies, it being agreed that after the service of notice or the commencement of a suit, or after final judgment for possession of the Premises, Landlord may receive and collect any Rent due, and the payment
of said Rent shall not waive or affect said notice, suit or judgment. 
 ARTICLE 13 

CONDEMNATION 
 If
the whole or any part of the Premises, Building or Project shall be taken by power of eminent domain or condemned by any competent authority for any public or quasi-public use or purpose, or if any adjacent property or street shall be so taken or
condemned, or reconfigured or vacated by such authority in such manner as to require the use, reconstruction or remodeling of any part of the Premises, Building or Project, or if Landlord shall grant a deed or other instrument in lieu of such taking
by eminent domain or condemnation, Landlord shall have the option to terminate this Lease effective as of the date possession is required to be surrendered to the authority. If more than ten percent (10%) of the rentable square feet of the
Premises is taken or the taking would prevent or materially interfere with Tenant’s use of the Premises, Tenant shall have the option to terminate this Lease effective as of the date possession is required to be surrendered to the authority.
Tenant shall not because of any such taking assert any claim against Landlord or the authority for any compensation because of such taking and Landlord shall be entitled to the entire award or payment in connection therewith, except that Tenant
shall have the right to file any separate claim available to Tenant for any taking of Tenant’s personal property and fixtures belonging to Tenant and removable by Tenant upon expiration of the Lease Term pursuant to the terms of this Lease, and
for moving expenses, so long as such claims do not diminish the award available to Landlord, its ground lessor with respect to the Building or Project or its mortgagee, and such claim is payable separately to Tenant. All Rent shall be apportioned as
of the date of such termination. If any part of the Premises shall be taken, and this Lease shall not be terminated in connection therewith, the Rent shall be proportionately abated. Tenant hereby waives any and all rights it might otherwise have
pursuant to Section 1265.130 of the California Code of Civil Procedure. 
 ARTICLE 14 

ASSIGNMENT AND SUBLETTING 

14.1 Transfers. Tenant shall not, without the prior written consent of Landlord, assign, mortgage, pledge, hypothecate,
encumber, or permit any lien to attach to, or otherwise transfer, this Lease or any interest hereunder, permit any assignment, or other transfer of this Lease or any interest hereunder by operation of law, sublet the Premises or any part thereof, or
enter into any license or concession agreements or otherwise permit the occupancy or use of the Premises or any part thereof by any persons other than Tenant and its employees and contractors (all of the foregoing are hereinafter sometimes referred
to individually as a “Transfer” and collectively as “Transfers” and any person to whom any Transfer is made or sought to be made is hereinafter sometimes referred to as a “Transferee”). If Tenant
desires Landlord’s consent to any Transfer, Tenant shall notify Landlord in writing, which notice (the “Transfer Notice”) shall include (i) the proposed effective date of the Transfer, which shall not be less than fourteen
(14) days nor more than one hundred eighty (180) days after the date of delivery of the Transfer Notice, (ii) a description of the portion of the Premises to be transferred (the “Subject Space”), (iii) all of the
terms of the proposed Transfer and the consideration therefor, including calculation of the “Transfer Premium”, as that term is defined in Section 14.3 below, in connection with such Transfer, the name and address of the proposed
Transferee, and an executed copy of all documentation 

  
 21 

 
effectuating the proposed Transfer, including all operative documents to evidence such Transfer, and (iv) current financial statements of the proposed Transferee certified by an officer,
partner or owner thereof, business credit and personal references and history of the proposed Transferee and any other information reasonably required by Landlord which will enable Landlord to determine the financial responsibility, character, and
reputation of the proposed Transferee, nature of such Transferee’s business and proposed use of the Subject Space. Any Transfer made without Landlord’s prior written consent shall, at Landlord’s option, be null, void and of no effect,
and shall, at Landlord’s option, constitute a default by Tenant under this Lease. Whether or not Landlord consents to any proposed Transfer, Tenant shall reimburse Landlord for its out-of-pocket review and processing fees which shall not exceed
Two Thousand Five Hundred Dollars ($2,500) in any one instance, and Tenant shall also reimburse Landlord for any reasonable out-of-pocket professional fees (including, without limitation, attorneys’, accountants’, architects’,
engineers’ and consultants’ fees) incurred by Landlord, within thirty (30) days after written request therefor by Landlord accompanied by reasonable back-up documentation. Notwithstanding anything to the contrary contained in this
Section 14.1, so long as Tenant delivers to Landlord (i) at least fifteen (15) business days prior written notice of its intention to assign or sublease the Premises to any Related Entity, which notice shall set forth the name of the
Related Entity, (ii) a copy of the proposed agreement pursuant to which such assignment or sublease shall be effectuated, and (iii) such other information concerning the Related Entity as Landlord may reasonably require, including without
limitation, information regarding any change in the proposed use of any portion of the Premises and any financial information with respect to such Related Entity, and so long as (a) any change in the proposed use of the subject portion of the
Premises is in conformance with the uses permitted to be made under this Lease and do not involve the use or storage of any Hazardous Materials (other than nominal amounts of ordinary household cleaners, office supplies and janitorial supplies which
are not regulated by any environmental laws), and (b) at the time of the proposed assignment or sublease, the net profits and financial condition of the Related Entity is reasonably adequate and sufficient in relation to the then remaining
obligations of Tenant under this Lease (as reasonably determined by Landlord), then Tenant may assign this Lease or sublease any portion of the Premises (1) to any Related Entity, or (2) in connection with any merger, consolidation or sale
of substantially all of the assets of Tenant, without having to obtain the prior written consent of Landlord thereto (each such transfer shall be referred to herein as a “Permitted Transfer”). Any Permitted Transfer shall in no way
relieve Tenant of any liability Tenant may have under this Lease and such assignee or sublessee shall be jointly and severally liable with Tenant hereunder. For purposes of this Section 14.1, the term “Related Entity” shall
mean any entity controlled by, under control with, or in control of Tenant and such entity shall have at least substantially the same net worth as Tenant. The term “control” as used in the immediately preceding sentence shall mean
having direct ownership of fifty percent (50%) or more of the ownership interests of an entity and having the ability to direct the management and policies of such entity. 

14.2 Landlord’s Consent. Landlord shall not unreasonably withhold, condition or delay its consent to any proposed Transfer
of the Subject Space to the Transferee on the terms specified in the Transfer Notice. Without limitation as to other reasonable grounds for withholding consent, the parties hereby agree that it shall be reasonable under this Lease and under any
Applicable Laws for Landlord to withhold consent to any proposed Transfer where one or more of the following apply: 
 14.2.1 The Transferee
is engaged in a business which is not consistent with the quality of the Building or the Project; 
 14.2.2 The Transferee intends to use
the Subject Space for purposes which are not permitted under this Lease; 
 14.2.3 The Transferee is either a governmental agency or
instrumentality thereof; 
 14.2.4 The Transferee is not a party of reasonable financial worth and/or financial stability in light of the
responsibilities to be undertaken in connection with the Transfer on the date consent is requested and in the event of an assignment of the Lease, then in no event shall the Transferee have a financial net worth less than Tenant’s net worth as
of the date of this Lease; 
 14.2.5 The proposed Transfer would cause a violation of another lease for space in the Project, or would give
an occupant of the Project a right to cancel its lease; 

  
 22 

 14.2.6 The terms of the proposed Transfer will allow the Transferee to exercise a right of
renewal, right of expansion, right of first offer, or other similar right held by Tenant; 
 14.2.7 Either the proposed Transferee, or any
person or entity which directly or indirectly, controls, is controlled by, or is under common control with, the proposed Transferee, (i) occupies space in the Project at the time of the request for consent, or (ii) is negotiating with
Landlord to lease space in the Project at such time, or (iii) has negotiated with Landlord during the one hundred eighty (180)-day period immediately preceding the Transfer Notice; provided in each event that Landlord has space in the Building
reasonably capable of satisfying the proposed Transferee’s space requirement; 
 14.2.8 In Landlord’s reasonable judgment, the use
of the Premises by the proposed Transferee (i) would not be comparable to the types of office uses of other tenants in the Project, (ii) would entail Alterations which would lessen the value of the Tenant Improvements in the Premises,
(iii) would result in more than allowed density of occupants per square foot of the Premises, as set forth in Section 5.2 above, (iv) would increase the burden on elevators or other Building systems or equipment over the burden
thereon prior to the proposed Transfer, or (v) would require increased services by Landlord; 
 14.2.9 An Event of Default, or an event
which with the giving of notice or the passage of time, or both, would constitute an Event of Default, of the terms, covenants and conditions of this Lease has occurred; 

14.2.10 The form of the proposed sublease and consent is not in a form reasonably satisfactory to Landlord and/or does not comply with the
applicable provisions of this Article 14; or 
 14.2.11 The rental and other terms and conditions of the sublease are the same as those
contained in the proposed sublease furnished to Landlord pursuant to Section 14.1. 
 If Landlord consents to any Transfer pursuant to
the terms of this Section 14.2 (and does not exercise any recapture rights Landlord may have under Section 14.4 of this Lease), Tenant may within six (6) months after Landlord’s consent, but not later than the expiration of said
six-month period, enter into such Transfer of the Premises or portion thereof, upon substantially the same terms and conditions as are set forth in the Transfer Notice furnished by Tenant to Landlord pursuant to Section 14.1 of this Lease,
provided that if there are any changes in the terms and conditions from those specified in the Transfer Notice (i) such that Landlord would initially have been entitled to refuse its consent to such Transfer under this Section 14.2, or
(ii) which would cause the proposed Transfer to be more favorable to the Transferee than the terms set forth in Tenant’s original Transfer Notice, Tenant shall again submit the Transfer to Landlord for its approval and other action under
this Article 14 (including Landlord’s right of recapture, if any, under Section 14.4 of this Lease). Notwithstanding anything to the contrary herein, Tenant hereby expressly waives all rights provided under California Civil Code
Section 1995.310, and any similar or successor statute or law in effect or any amendment thereof during the Lease Term and Tenant hereby acknowledges and agrees that, if it is determined by a court of law that Landlord has withheld or delayed
its consent to a proposed sublet or assignment of all or any portion of Tenant’s interest in this Lease in a manner which results in a breach of Landlord’s obligations under this Article 14, then the sole remedy of Tenant and any proposed
Transferee as a result of such breach shall be to seek a declaratory judgment and/or injunctive relief. Tenant shall indemnify, defend and hold harmless Landlord from any and all Claims involving any third party or parties (including without
limitation Tenant’s proposed subtenant or assignee) who claim they were damaged by Landlord’s wrongful withholding or conditioning of Landlord’s consent. 

14.3 Transfer Premium. If Landlord consents to a Transfer, as a condition thereto which the parties hereby agree is reasonable,
Tenant shall pay to Landlord fifty percent (50%) of any “Transfer Premium,” as that term is defined in this Section 14.3, received by Tenant from such Transferee. “Transfer Premium” shall mean all rent,
additional rent or other consideration payable by such Transferee in connection with the Transfer in excess of the Rent and Additional Rent payable by Tenant under this Lease during the term of the Transfer on a per rentable square foot basis if
less than all of the Premises is transferred, after deducting the reasonable expenses incurred by Tenant for (i) any reasonable Alterations to the Premises made by Tenant (and consented to by Landlord) in connection with the Transfer,
(ii) any free base rent reasonably provided to the Transferee, and (iii) any brokerage commissions customary in the industry in connection with the Transfer (collectively, “Tenant’s Costs”). “Transfer
Premium” shall also include, but not be limited 

  
 23 

 
to, key money, bonus money or other cash consideration paid by Transferee to Tenant in connection with such Transfer, and any payment in excess of fair market value for services rendered by
Tenant to Transferee or for assets, fixtures, inventory, equipment, or furniture transferred by Tenant to Transferee in connection with such Transfer. For the purposes of calculating the Transfer Premium on a monthly basis, (A) Tenant’s
Costs shall be amortized over the remaining term of this Lease, and (B) the Rent paid for the Subject Space shall be computed after adjusting such rent to the actual effective rent to be paid, taking into consideration any and all leasehold
concessions granted in connection therewith, including, but not limited to, any rent credit and tenant improvement allowance. For purposes of calculating any such effective rent all such concessions shall be amortized on a straight-line basis over
the relevant term. 
 14.4 Landlord’s Option as to Subject Space. Notwithstanding anything to the contrary contained in
this Article 14, in the event Tenant desires to sublease the entire Premises for the then remaining Term of the Lease, then Landlord shall have the option, by giving written notice to Tenant within twenty (20) days after receipt of any Transfer
Notice, to recapture the Premises. Such recapture shall cancel and terminate this Lease as of the date stated in the Transfer Notice as the effective date of the proposed Transfer. If Landlord declines, or fails to elect in a timely manner, to
recapture the Premises under this Section 14.4, then, provided Landlord has consented to the proposed Transfer, Tenant shall be entitled to proceed to transfer the Premises to the proposed Transferee, subject to provisions of this Article 14.

 14.5 Effect of Transfer. If Landlord consents to a Transfer, (i) the terms and conditions of this Lease shall in no
way be deemed to have been waived or modified, (ii) such consent shall not be deemed consent to any further Transfer by either Tenant or a Transferee, (iii) Tenant shall deliver to Landlord, promptly after execution, an original executed
copy of all documentation pertaining to the Transfer in form reasonably acceptable to Landlord, (iv) Tenant shall furnish upon Landlord’s request a complete statement, certified by an independent certified public accountant, or
Tenant’s chief financial officer, setting forth in detail the computation of any Transfer Premium Tenant has derived and shall derive from such Transfer, and (v) no Transfer relating to this Lease or agreement entered into with respect
thereto, whether with or without Landlord’s consent, shall relieve Tenant or any guarantor of the Lease from any liability under this Lease, including, without limitation, in connection with the Subject Space and, in the event of a Transfer of
Tenant’s entire interest in this Lease, the liability of Tenant and such Transferee shall be joint and several. Landlord or its authorized representatives shall have the right at all reasonable times to audit the books, records and papers of
Tenant relating to any Transfer, and shall have the right to make copies thereof. If the Transfer Premium respecting any Transfer shall be found understated, Tenant shall, within thirty (30) days after demand, pay the deficiency, and if
understated by more than five percent (5%), Tenant shall pay Landlord’s costs of such audit. Notwithstanding anything to the contrary contained in this Article 14, Landlord, at its option in its sole and absolute discretion, may require, as a
condition to the validity of any Transfer, that both Tenant and such Transferee enter into a separate written agreement directly with Landlord (a “Transfer Agreement”), which Transfer Agreement, among other things, shall create
privity of contract between Landlord and such Transferee with respect to the provisions of this Article 14, and shall contain such terms and provisions as Landlord may reasonably require, including, without limitation, the following: (A) such
Transferee’s agreement to be bound by all the obligations of Tenant under this Lease (including, but not limited to, Tenant’s obligation to pay Rent), provided that, in the event of a Transfer of less than the entire Premises, the
obligations to which such Transferee shall agree to be so bound shall be prorated on a basis of the number of rentable square feet of the Subject Space in proportion to the number of square feet in the Premises; (B) such Transferee’s
acknowledgment of, and agreement that such Transfer shall be subordinate and subject to, Landlord’s rights under Section 19.2.4 of this Lease; and (C) Tenant’s and such Transferee’s recognition of and agreement to be bound
by all the terms and provisions of this Article 14, including, but not limited to, any such terms and provisions which Landlord, at its option, requires to be expressly set forth in such Transfer Agreement. Upon the occurrence of any default by
Transferee under such Transfer, Landlord shall have the right, at its option, but not the obligation, on behalf of Tenant, to pursue any or all of the remedies available to Tenant under such Transfer or at law or in equity (all of which remedies
shall be distinct, separate and cumulative). 
 14.6 Additional Transfers. For purposes of this Lease, the term
“Transfer” shall also include (i) if Tenant is a partnership or limited liability company, the withdrawal or change, voluntary, involuntary or by operation of law, of fifty percent (50%) or more of the partners or members,
or transfer of fifty percent (50%) or more of partnership or membership interests, or the dissolution of the partnership without immediate reconstitution thereof, and (ii) if Tenant is a closely held corporation (i.e., whose stock
is not publicly held and not traded through an exchange or over the counter), 

  
 24 

 
(A) the dissolution of Tenant or (B) the sale or other transfer of an aggregate of fifty percent (50%) or more of the voting shares of Tenant (other than to immediate family members by
reason of gift or death), or (C) the sale of an aggregate of fifty percent (50%) or more of the value of the unencumbered assets of Tenant. 

14.7 Occurrence of Default. Any Transfer hereunder shall be subordinate and subject to the provisions of this Lease, and if this
Lease shall be terminated during the term of any Transfer, Landlord shall have the right to: (i) treat such Transfer as cancelled and repossess the Subject Space by any lawful means, or (ii) require that such Transferee attorn to and
recognize Landlord as its landlord under any such Transfer. If an Event of Default by Tenant has occurred under this Lease, Landlord is hereby irrevocably authorized, as Tenant’s agent and attorney-in-fact, to direct any Transferee to make all
payments under or in connection with the Transfer directly to Landlord (which Landlord shall apply towards Tenant’s obligations under this Lease). Such Transferee shall rely on any representation by Landlord that an Event of Default by Tenant
has occurred hereunder, without any need for confirmation thereof by Tenant. Upon any assignment of this Lease, the assignee shall assume in writing all obligations and covenants of Tenant thereafter to be performed or observed under this Lease. No
collection or acceptance of rent by Landlord from any Transferee shall be deemed a waiver of any provision of this Article 14 or the approval of any Transferee or a release of Tenant from any obligation under this Lease, whether theretofore or
thereafter accruing. In no event shall Landlord’s enforcement of any provision of this Lease against any Transferee be deemed a waiver of Landlord’s right to enforce any term of this Lease against Tenant or any other person. If
Tenant’s obligations hereunder have been guaranteed, Landlord’s consent to any Transfer shall not be effective unless the guarantor also consents to such Transfer. 

ARTICLE 15 

SURRENDER OF PREMISES; OWNERSHIP AND 

REMOVAL OF TRADE FIXTURES 

15.1 Surrender of Premises. No act or thing done by Landlord or any agent or employee of Landlord during the Lease Term shall be
deemed to constitute an acceptance by Landlord of a surrender of the Premises unless such intent is specifically acknowledged in writing by Landlord. The delivery of keys to the Premises to Landlord or any agent or employee of Landlord shall not
constitute a surrender of the Premises or effect a termination of this Lease, whether or not the keys are thereafter retained by Landlord, and notwithstanding such delivery Tenant shall be entitled to the return of such keys at any reasonable time
upon request until this Lease shall have been properly terminated. The voluntary or other surrender of this Lease by Tenant, whether accepted by Landlord or not, or a mutual termination hereof, shall not work a merger, and at the option of Landlord
shall operate as an assignment to Landlord of all subleases or subtenancies affecting the Premises or terminate any or all such sublessees or subtenancies. 

15.2 Removal of Tenant Property by Tenant. On or before the expiration or earlier termination of this Lease, Tenant shall remove
at Tenant’s expense (i) all of Tenant’s Property (defined below) and Tenant’s signage from the Premises and other portions of the Project, (ii) any Permitted Alterations, and (iii) any other Alterations Landlord, by
notice to Tenant given at the time Landlord has consented to such Alteration, has required Tenant to remove, and Tenant shall repair any damage caused by all of such removal activities. “Tenant’s Property” means all equipment, trade
fixtures, furnishings, all telephone, data, and other cabling and wiring (including any cabling and wiring associated with the Wi-Fi Network, if any) installed or caused to be installed by Tenant (including any cabling and wiring, installed above
the ceiling of the Premises or below the floor of the Premises), inventories, goods and personal property of Tenant. Any of Tenant’s Property not so removed by Tenant as required herein shall be deemed abandoned and may be stored, removed, and
disposed of by Landlord at Tenant’s expense, and Tenant waives all claims against Landlord for any damages resulting from Landlord’s retention and disposition of such property; provided, however, Tenant shall remain liable to Landlord for
all costs incurred in storing and disposing of such abandoned property of Tenant. Landlord may elect to take responsibility to remove any such wiring or cabling installed above the ceiling or beneath the floors of the Premises, in which case Tenant
shall pay Landlord for the actual reasonable cost incurred by Landlord therefor, within thirty (30) days after being billed for the same. Notwithstanding anything contained herein to the contrary, in the event Tenant elects, in accordance with
the terms, covenants and conditions of this Lease, to remove the existing corridors located on the North or South sides of the eleventh (11th) floor of the Building (as shown on Exhibit
E attached hereto), at the expiration or earlier termination of the Lease, Landlord shall have the right (but not the obligation) to restore such corridors following Lease termination to Building standard condition and Tenant shall be
obligated to reimburse 

  
 25 

 
Landlord for all reasonable costs incurred in connection therewith within thirty (30) days after receipt of an invoice therefor, together with reasonable back-up documentation. In the event
that Tenant exercises its Option in accordance with the terms of Section 2.2 above, then Tenant shall only be obligated to reimburse Landlord for one-third of the reasonable restoration costs incurred by Landlord pursuant to the immediately
preceding sentence and, in the event that the Lease Term is extended such that Tenant occupies the Premises for at least one hundred eighty (180) consecutive months, then Tenant shall not be obligated to reimburse Landlord for any restoration
costs incurred by Landlord pursuant to the immediately preceding sentence. In the event Tenant elects, in accordance with the terms, covenants and conditions of this Lease, to remove the existing corridors located on the East side of the eleventh
(11th) floor of the Building, Tenant shall have no obligation to restore such corridor on the expiration or earlier termination of the Lease. The terms of this Section 15.2 shall survive
the expiration or earlier termination of the Lease. All Alterations except those which Landlord requires Tenant to remove shall remain in the Premises as the property of Landlord. If the Premises are not surrendered at the expiration of the Term or
earlier termination of this Lease, and in accordance with this Article 15, Tenant shall continue to be responsible for the payment of Rent (as the same may be increased pursuant to Article 16 below) until the Premises are so surrendered in
accordance with said provisions. 
 ARTICLE 16 

HOLDING OVER 
 If
Tenant holds over after the expiration of the Lease Term or earlier termination thereof, with or without the express or implied consent of Landlord, such tenancy shall be at the sufferance of Landlord and shall not constitute a renewal hereof or an
extension for any further term, and in such case Rent for the full hold over period shall be payable in advance, as minimum damages and not as a penalty, at a monthly rate equal to (A) 150% of the Rent applicable during the last rental period
of the Lease Term under this Lease during the first sixty (60) days of holdover, and (B) 200% of the Rent applicable during the last rental period of the Lease Term under this Lease thereafter. During any such holdover period, Tenant shall
pay a full month’s rent for each month, or any portion thereof, that tenancy is extended beyond the Lease Expiration Date. Such holdover tenancy shall be subject to every other applicable term, covenant and agreement contained herein. For
purposes of this Article 16, a holding over shall include Tenant’s remaining in the Premises after the expiration or earlier termination of the Lease Term to remove any Alterations or Non Standard Tenant Improvements located within the Premises
and replace the same with Building Standard Tenant Improvements to the extent such removal and replacement is required in this Lease or the Tenant Work Letter. Nothing contained in this Article 16 shall be construed as consent by Landlord to any
holding over by Tenant, and Landlord expressly reserves the right to require Tenant to surrender possession of the Premises to Landlord as provided in this Lease upon the expiration or other termination of this Lease. The provisions of this Article
16 shall not be deemed to limit or constitute a waiver of any other rights or remedies of Landlord provided herein or at law. If Tenant fails to surrender the Premises upon the termination or expiration of this Lease, in addition to any other
liabilities to Landlord accruing therefrom, Tenant shall protect, defend, indemnify and hold Landlord harmless from all Claims resulting from such failure, including, without limitation, the generality of the foregoing, so long as Landlord has
provided notice (oral or written) to Tenant that another tenant intends to occupy the Premises, any Claims made by any succeeding tenant founded upon such failure to surrender and any lost profits to Landlord resulting therefrom. 

ARTICLE 17 

ESTOPPEL CERTIFICATES 

Within ten (10) days following a request in writing by Landlord, Tenant shall execute, acknowledge and deliver to Landlord an estoppel
certificate, which, as submitted by Landlord, shall be in the form as may be required by any prospective mortgagee or purchaser of the Project (or any portion thereof), indicating therein any exceptions thereto that may exist at that time, and shall
also contain any other information reasonably requested by Landlord or Landlord’s mortgagee or prospective mortgagee. Any such certificate may be relied upon by any prospective mortgagee or purchaser of all or any portion of the Project. Tenant
shall execute and deliver whatever other instruments may be reasonably required for such purposes. In addition, no more than once in any twelve (12) month period, if requested by Landlord, Tenant shall provide to Landlord, any actual or
potential purchaser, mortgagee or ground lessor or any representative of any of the foregoing, copies of Tenant’s annual financial statements (audited if available), certified as 

  
 26 

 
true and correct by the president or chief financial officer of Tenant; provided that so long as the stock of Tenant is publicly traded, documents on file with the Securities and Exchange
Commission and available to Landlord shall satisfy such financial reporting requirements. Failure of Tenant to timely execute, acknowledge and deliver such estoppel certificate or other instruments to Landlord shall constitute an acceptance of the
Premises and an acknowledgment by Tenant that statements included in the estoppel certificate are true and correct, without exception. In addition, if Tenant fails to execute and deliver to Landlord an estoppel certificate on or prior to the
expiration of five (5) days following a second request in writing from Landlord after the expiration of the ten (10) day period following Landlord’s initial notice to Tenant, then Tenant shall be liable to Landlord, and shall
indemnify, defend and hold Landlord harmless from and against any Claims incidental, consequential, or otherwise, arising or accruing directly or indirectly, from any failure of Tenant to execute or deliver to Landlord any such estoppel certificate.

 ARTICLE 18 

SUBORDINATION 

18.1 Subordination; Non-Disturbance and Attornment. This Lease shall be subject and subordinate to all present and future ground
or underlying leases of the Building or Project and to the lien of any mortgage, trust deed or other encumbrances now or hereafter in force against the Building or Project or any part thereof, if any, and to all renewals, extensions, modifications,
consolidations and replacements thereof, and to all advances made or hereafter to be made upon the security of such mortgages or trust deeds, unless the holders of such mortgages, trust deeds or other encumbrances, or the lessors under such ground
lease or underlying leases, require in writing that this Lease be superior thereto. Tenant covenants and agrees in the event any proceedings are brought for the foreclosure of any such mortgage or deed in lieu thereof (or if any ground lease is
terminated), to attorn, without any deductions or set-offs whatsoever, to the lienholder or purchaser or any successors thereto upon any such foreclosure sale or deed in lieu thereof (or to the ground lessor), if so requested to do so by such
purchaser or lienholder or ground lessor, and to recognize such purchaser or lienholder or ground lessor as the lessor under this Lease, provided such lienholder or purchaser or ground lessor shall agree to accept this Lease and not disturb
Tenant’s occupancy, so long as Tenant timely pays the rent and observes and performs the terms, covenants and conditions of this Lease to be observed and performed by Tenant. Landlord’s interest herein may be assigned as security at any
time to any lienholder. Tenant shall, within ten (10) days of request by Landlord, execute such further instruments or assurances as Landlord may reasonably deem necessary to evidence or confirm the subordination or superiority of this Lease to
any such mortgages, trust deeds, ground leases or underlying leases. Tenant waives the provisions of any current or future statute, rule or law which may give or purport to give Tenant any right or election to terminate or otherwise adversely affect
this Lease and the obligations of the Tenant hereunder in the event of any foreclosure proceeding or sale. 
 Landlord hereby represents
that, as of the date hereof, the Building and the Project are not encumbered by any mortgage, deed of trust, or ground lease. Notwithstanding anything to the contrary contained herein, as a condition precedent to Tenant’s obligation to
subordinate this Lease to any future mortgage, deed of trust, ground lease or other lease, Landlord shall obtain from the holder of such future mortgage or deed of trust or the lessor under such future ground lease or other lease a non-disturbance
agreement in favor of Tenant in commercially reasonable form that provides in substance that, so long as Tenant shall not then be in default in the performance of any of its obligations under this Lease beyond any applicable notice and cure period,
Tenant’s possession of the Premises in accordance with this Lease shall not be disturbed by such mortgagee or lessor or any successor or purchaser at a foreclosure sale (as the case may be) which shall succeed to the rights of Landlord under
this Lease. 
 18.2 Notice to Lienholder or Ground Lessor. Notwithstanding anything to the contrary contained in this Lease,
upon receipt by Tenant of notice from any holder of a mortgage, trust deed or other encumbrance in force against the Building or the Project or any part thereof which includes the Premises or any lessor under a ground lease or underlying lease of
the Building or the Project, or from Landlord, which notice sets forth the address of such lienholder or ground lessor, no notice from Tenant to Landlord shall be effective unless and until a copy of the same is given to such lienholder or ground
lessor at the appropriate address therefor (as specified in the above-described notice or at such other places as may be designated from time to time in a notice to Tenant in accordance with Section 28.19 below), and the curing of any of
Landlord’s defaults by such lienholder or ground lessor within a reasonable period of time after such notice from Tenant (including a reasonable period of time to obtain possession of the Building or the Project, as the case

  
 27 

 
may be, if such lienholder or ground lessor elects to do so) shall be treated as performance by Landlord. For the purposes of this Article 18, the term “mortgage” shall include a
mortgage on a leasehold interest of Landlord (but not a mortgage on Tenant’s leasehold interest hereunder). 
 18.3 Assignment of
Rents. With reference to any assignment by Landlord of Landlord’s interest in this Lease, or the Rent payable to Landlord hereunder, conditional in nature or otherwise, which assignment is made to any holder of a mortgage, trust deed or
other encumbrance in force against the Building or the Project or any part thereof which includes the Premises or to any lessor under a ground lease or underlying lease of the Building or the Project, Tenant agrees that (i) the execution of any
such assignment by Landlord, and the acceptance thereof by such lienholder or ground lessor, shall never be treated as an assumption by such lienholder or ground lessor of any of the obligations of Landlord under this Lease, unless such lienholder
or ground lessor shall, by notice to Tenant, specifically otherwise elect; and (ii) notwithstanding delivery to Tenant of the notice required by Section 18.2, above, such lienholder or ground lessor, respectively, shall be treated as
having assumed Landlord’s obligations under this Lease only upon such lienholder’s foreclosure of any such mortgage, trust deed or other encumbrance, or acceptance of a deed in lieu thereof, and taking of possession of the Building or the
Project or applicable portion thereof, or such ground lessor’s termination of any such ground lease or underlying leases and assumption of Landlord’s position hereunder, as the case may be. 

ARTICLE 19 

DEFAULTS; REMEDIES 

19.1 Events of Default. The occurrence of any of the following shall constitute an “Event of Default” of this
Lease by Tenant: 
 19.1.1 Any failure by Tenant to pay any Rent or any other charge required to be paid under this Lease, or any part
thereof, when due and such default shall continue for three (3) days after Landlord shall have given Tenant written notice of such default; or 

19.1.2 Except where a specific time period is otherwise set forth for Tenant’s performance pursuant to this Section 19.1, any
failure by Tenant to observe or perform any other provision, covenant or condition of this Lease to be observed or performed by Tenant where such failure continues for thirty (30) days after written notice thereof from Landlord to Tenant;
provided that if the nature of such default is such that the same cannot reasonably be cured within a thirty (30) day period, Tenant shall not be deemed to be in default if it diligently commences such cure within such period and thereafter
diligently proceeds to rectify and cure such default and actually completes the cure of such default within ninety (90) days from receipt of Landlord’s notice; or 

19.1.3 To the extent permitted by law, a general assignment by Tenant or any guarantor of this Lease for the benefit of creditors, or the
taking of any corporate action in furtherance of bankruptcy or dissolution whether or not there exists any proceeding under an insolvency or bankruptcy law, or the filing by or against Tenant or any guarantor of any proceeding under an insolvency or
bankruptcy law, unless in the case of a proceeding filed against Tenant or any guarantor the same is dismissed within sixty (60) days, or the appointment of a trustee or receiver to take possession of all or substantially all of the assets of
Tenant or any guarantor, unless possession is restored to Tenant or such guarantor within thirty (30) days, or any execution or other judicially authorized seizure of all or substantially all of Tenant’s assets located upon the Premises or
of Tenant’s interest in this Lease, unless such seizure is discharged within thirty (30) days; or 
 19.1.4 Abandonment of all or
a substantial portion of the Premises by Tenant while Tenant is in default of any other material term, covenant or condition of this Lease; or 

19.1.5 The failure by Tenant to observe or perform according to, or to deliver the documents required within the time periods specified by,
the provisions of Articles 10, 14, 17 or 18 of this Lease where such failure continues for more than three (3) business days after notice from Landlord. 

  
 28 

 The notice periods provided herein are in lieu of, and not in addition to, any notice required
under California Code of Civil Procedure Section 1161 or any similar or successor law. 
 19.2 Remedies Upon Default.
Upon the occurrence of any Event of Default by Tenant of any of the terms, covenants or conditions of this Lease, Landlord shall have, in addition to any other remedies available to Landlord at law or in equity (all of which remedies shall be
distinct, separate and cumulative), the option to pursue any one or more of the following remedies, each and all of which shall be cumulative and nonexclusive, without any notice or demand whatsoever. 

19.2.1 Terminate this Lease, in which event Tenant shall immediately surrender the Premises to Landlord, and if Tenant fails to do so,
Landlord may, without prejudice to any other remedy which it may have for possession or arrearages in rent, enter upon and take possession of the Premises and expel or remove Tenant and any other person who may be occupying the Premises or any part
thereof, without being liable for prosecution or any claim or damages therefor; and Landlord may recover from Tenant the following: 
 (i)
The worth at the time of any unpaid rent which has been earned at the time of such termination; plus 
 (ii) The worth at the time of award
of the amount by which the unpaid rent which would have been earned after termination until the time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus 

(iii) The worth at the time of award of the amount by which the unpaid rent for the balance of the Lease Term after the time of award exceeds
the amount of such rental loss that Tenant proves could have been reasonably avoided; plus 
 (iv) Any other amount necessary to compensate
Landlord for all the detriment proximately caused by Tenant’s failure to perform its obligations under this Lease or which in the ordinary course of things would be likely to result therefrom, specifically including but not limited to,
brokerage commissions and advertising expenses incurred, expenses of remodeling the Premises or any portion thereof for a new tenant, whether for the same or a different use, and any special concessions made to obtain a new tenant; and 

(v) At Landlord’s election, such other amounts in addition to or in lieu of the foregoing as may be permitted from time to time by
applicable law. 
 The term “rent” as used in this Section 19.2 shall be deemed to be and to mean all sums of every
nature required to be paid by Tenant pursuant to the terms of this Lease, whether to Landlord or to others. As used in Paragraphs 19.2.1(i) and (ii) above, the “worth at the time of award” shall be computed by allowing interest at the
rate set forth in Article 24 of this Lease, but in no case greater than the maximum amount of such interest permitted by law. As used in Paragraph 19.2.1(iii) above, the “worth at the time of award” shall be computed by discounting such
amount at the discount rate of the Federal Reserve Bank of San Francisco at the time of award plus two percent (2%). 
 19.2.2 Landlord
shall have the remedy described in California Civil Code Section 1951.4 (lessor may continue lease in effect after lessee’s breach and abandonment and recover rent as it becomes due, if lessee has the right to sublet or assign, subject
only to reasonable limitations). Accordingly, if Landlord does not elect to terminate this Lease on account of any Event of Default by Tenant, Landlord may, from time to time, without terminating this Lease, enforce all of its rights and remedies
under this Lease, including the right to recover all rent as it becomes due. 
 19.2.3 Landlord shall at all times have the rights and
remedies (which shall be cumulative with each other and cumulative and in addition to those rights and remedies available under Sections 19.2.1 and 19.2.2 above, or any law or other provision of this Lease), without prior demand or notice except as
required by applicable law, to seek any declaratory, injunctive or other equitable relief, and specifically enforce this Lease, or restrain or enjoin a violation or breach of any provision hereof. 

  
 29 

 19.2.4 If Landlord elects to terminate this Lease on account of any Event of Default by Tenant,
as set forth in this Article 19, then Landlord shall have the right, at Landlord’s option in its sole discretion, (i) to terminate any and all assignments, subleases, licenses, concessions or other consensual arrangements for possession
entered into by Tenant and affecting the Premises, in which event Landlord shall have the right to repossess such affected portions of the Premises by any lawful means, or (ii) to succeed to Tenant’s interest in any or all such
assignments, subleases, licenses, concessions or arrangements, in which event Landlord may require any assignees, sublessees, licensees or other parties thereunder to attorn to and recognize Landlord as its assignor, sublessor, licensor,
concessionaire or transferor thereunder. In the event of Landlord’s election to succeed to Tenant’s interest in any such assignments, subleases, licenses, concessions or arrangements, Tenant shall, as of the date of notice by Landlord of
such election, have no further right to or interest in the rent or other consideration receivable thereunder. 
 19.3 Form of Payment
After Default. Following the occurrence of any Event of Default by Tenant of any of the terms, covenants or conditions of this Lease, Landlord shall have the right to require that any or all subsequent amounts paid by Tenant to Landlord
hereunder, whether to cure the default in question or otherwise, be paid in the form of cash, money order, cashier’s or certified check drawn on an institution acceptable to Landlord, or by other means approved by Landlord, notwithstanding any
prior practice of accepting payments in any different form. 
 19.4 Efforts to Relet. No re-entry or repossession, repairs,
maintenance, changes, alterations and additions, reletting, appointment of a receiver to protect Landlord’s interests hereunder, or any other action or omission by Landlord shall be construed as an election by Landlord to terminate this Lease
or Tenant’s right to possession, or to accept a surrender of the Premises, nor shall same operate to release Tenant in whole or in part from any of Tenant’s obligations hereunder, unless express written notice of such intention is sent by
Landlord to Tenant. Tenant hereby irrevocably waives any right otherwise available under any law to redeem or reinstate this Lease. 
 19.5
Landlord’s Default. Landlord shall not be deemed to be in default hereunder unless such default shall remain uncured for more than thirty (30) days following receipt of written notice from Tenant to Landlord specifying the
nature of such default, or such longer period as reasonably may be required to correct such default (provided that Landlord has commenced such cure within such thirty (30) day period and is diligently and continuously prosecuting the same to
completion). If Landlord shall fail to perform any of the terms, provisions, covenants or conditions to be performed or complied with by Landlord under Section 7.2 of this Lease with respect only to the Premises (such terms, provisions,
covenants or conditions are referred to herein, collectively, as “Landlord Repair Obligations”) after expiration of all applicable notice and cure periods for Landlord’s and any mortgagee’s benefit as set forth in this
Lease, then Tenant may, at Tenant’s option and risk, but without any obligation to do so, after delivery of an additional twenty (20) day prior written notice to Landlord, perform such Landlord Repair Obligations on Landlord’s behalf.
If Tenant so performs any of such Landlord Repair Obligations hereunder, then Tenant will perform such Landlord Repair Obligations (i) in compliance with all applicable laws, regulations and requirements to which Landlord would be subject under
this Lease (if Landlord were performing such Landlord Repair Obligations), (ii) in a good workmanlike manner using materials of a quality and grade at least equal to that in place as of the date of delivery of the Premises to Tenant, if
applicable, (iii) without interfering with the rights of other tenants of the Building or Project, and (iv) in compliance with the terms and provisions of Section 8.2 hereof, as applicable. Tenant will promptly assign to Landlord any
warranties or guaranties in respect of any Landlord Repair Obligations. If Tenant so performs any of such Landlord Repair Obligations hereunder, the full amount of the fair and reasonable costs and expenses incurred by Tenant shall be owing by
Landlord to Tenant, and Landlord shall pay to Tenant the full undisputed amount thereof within thirty (30) days of Landlord’s receipt of Tenant’s written demand therefor together with reasonable evidence verifying the amount of such
costs and expenses. 
 ARTICLE 20 

COVENANT OF QUIET ENJOYMENT 

Landlord covenants that Tenant, on paying the Rent, charges for services and other payments herein reserved and on keeping, observing and
performing all the other terms, covenants, conditions, provisions and agreements herein contained on the part of Tenant to be kept, observed and performed, shall, during the Lease Term, peaceably and quietly have, hold and enjoy the Premises subject
to the terms, covenants, conditions, provisions and agreements hereof without interference by any persons lawfully claiming by or through Landlord. The foregoing covenant is in lieu of any other covenant express or implied. 

  
 30 

 ARTICLE 21 

SECURITY DEPOSIT 

Concurrently with execution hereof, Tenant shall deposit with Landlord a security deposit (“Security Deposit”), in the amount
set forth in Section 8 of the Summary, as security for the full and faithful performance of Tenant’s obligations under this Lease. Landlord may (but shall not be required to) use the Security Deposit or any portion thereof to cure any
defaults on the part of Tenant or to compensate Landlord for any damage Landlord incurs as a result of Tenant’s failure to perform any of its covenants or obligations hereunder, it being understood that any use of the Security Deposit shall not
constitute a bar or defense to any of Landlord’s remedies under this Lease, at law or in equity. In such event, and upon written notice from Landlord to Tenant specifying the amount of the Security Deposit so utilized by Landlord and the
particular purpose for which such amount was applied, Tenant shall immediately deposit with Landlord an amount sufficient to return the Security Deposit to the amount specified in Section 8 of the Summary. Upon expiration of the Lease Term or
earlier termination, the Security Deposit shall be returned to Tenant, reduced by those amounts that may be required by Landlord to remedy defaults on the part of Tenant in the payment of Rent, to repair damages to the Premises caused by Tenant and
to clean the Premises. The portion of the deposit not so required shall be paid over to Tenant within sixty (60) days after expiration of the Term or earlier termination hereof. Landlord shall hold the Security Deposit for the foregoing
purposes; provided, however, that Landlord shall have no obligation to segregate the Security Deposit from its general funds or to pay interest thereon. If Landlord conveys or transfers its interest in the Premises, and as a part of such conveyance
or transfer, assigns its interest in this Lease and Security Deposit, or any portion thereof not previously applied, the Security Deposit shall be transferred to Landlord’s successor and the Landlord named herein shall be released and
discharged from any further liability to Tenant with respect to such Security Deposit. In no event shall any mortgagee or beneficiary under a mortgage or deed of trust encumbering all or any portion of the Project, or any purchaser of all or any
portion of the Project at a public or private foreclosure sale or exercise of a power of sale under such mortgage or deed of trust, have any liability or obligation whatsoever to Tenant or Tenant’s successors or assigns for the return of all or
any part of the Security Deposit in the event any such mortgagee, beneficiary or purchaser becomes a mortgagee in possession or succeeds to the interest of Landlord under this Lease unless, and then only to the extent that, such mortgagee,
beneficiary or purchaser has received all or any part of the Security Deposit. Tenant hereby waives (i) California Civil Code Section 1950.7 and any and all other Applicable Laws applicable to security deposits in the commercial context
(“Security Deposit Laws”), and (ii) any and all rights, duties and obligations either party may now or, in the future, will have relating to or arising from the Security Deposit Laws. Notwithstanding anything to the contrary
herein, the security deposit may additionally be retained and applied by Landlord (a) to offset Rent which is unpaid either before or after termination of this Lease, and (b) against other damages suffered by Landlord before or after
termination of this Lease. 
 ARTICLE 22 

SIGNS 
 22.1
Full Floors. Subject to Landlord’s prior written approval, which approval shall not be unreasonably withheld, conditioned or delayed, and provided all signs are in keeping with the quality, design and style of the Building and
Project, Tenant, if the Premises comprise an entire floor of the Building, at its sole cost and expense, may install identification signage anywhere in the Premises including in the elevator lobby of the Premises, provided that such signs must not
be visible from the exterior of the Building. Alternatively, Tenant may elect to have Landlord provide such identifying signage, which signage shall be comparable to that used by Landlord for other similar floors in the Building and shall comply
with Landlord’s Building standard signage program, in which event Landlord shall pay for the cost of the initial installation of such signage, and Tenant shall pay for the cost of any changes thereto. 

22.2 Multi-Tenant Floors. If other tenants occupy space on the floor on which the Premises is located, Tenant’s identifying
signage shall be provided by Landlord, and such signage shall be comparable to that used by Landlord for other similar floors in the Building and shall comply with Landlord’s Building standard signage program. Landlord shall pay for the cost of
the initial installation of such signage, and Tenant shall pay for the cost of any changes thereto. 

  
 31 

 22.3 Prohibited Signage and Other Items. Any signs, notices, logos, pictures, names
or advertisements which are installed and that have not been separately approved by Landlord may be removed without notice by Landlord at the sole expense of Tenant. Tenant may not install any signs on the exterior or roof of the Project or the
Common Areas. Any signs, window coverings, or blinds (even if the same are located behind the Landlord-approved window coverings for the Building), or other items visible from the exterior of the Premises or Building, shall be subject to the prior
approval of Landlord, in its sole discretion. 
 22.4 Building Directory. A building directory will be located in the lobby of
the Building. Tenant shall have the right, at Landlord’s expense, to designate one (1) name to be displayed on such directory. 

ARTICLE 23 

COMPLIANCE WITH LAW 

Tenant shall not do anything or suffer anything to be done in or about the Premises or the Project which will in any way conflict with any
Applicable Laws. At its sole cost and expense, Tenant shall promptly comply with all such Applicable Laws which relate to (i) Tenant’s use of the Premises, (ii) the Alterations or tenant improvements in the Premises, or (iii) the
Base Building, but, as to the Base Building, only to the extent such obligations are triggered by Tenant’s Alterations, the Tenant Improvements, or Tenant’s particular manner of use of the Premises. Should any standard or regulation now or
hereafter be imposed on Landlord or Tenant by a state, federal or local governmental body charged with the establishment, regulation and enforcement of occupational, health or safety standards for employers, employees, landlords or tenants, then
Tenant agrees, at its sole cost and expense, to comply promptly with such standards or regulations. 
 Without limiting the generality of
the above, Tenant shall promptly comply with all requirements of the Americans with Disabilities Act and the regulations promulgated under it in effect from time to time (“ADA Requirements”) relating to the conduct of Tenant’s
business. The judgment of any court of competent jurisdiction or the admission of Tenant in any judicial action, regardless of whether Landlord is a party thereto, that Tenant has violated any of the said governmental measures shall be conclusive of
that fact as between Landlord and Tenant. 
 Tenant shall have exclusive responsibility for compliance with ADA Requirements pertaining to
the interior of the Premises, including the design and construction of access thereto and egress therefrom. Landlord shall have responsibility for compliance with ADA Requirements and Title 24 standards which affect the Common Areas of the Building
(including, without limitation, common restrooms and paths of travel), subject to Tenant’s obligation to pay for its share of the expense of such compliance pursuant to Article 4 of this Lease. Tenant shall comply promptly with any direction of
any governmental authority having jurisdiction which imposes any duty upon Tenant or Landlord with respect to the Premises or with respect to the use or occupancy thereof. Tenant shall furnish Landlord with a copy of any such direction promptly
after receipt of the same. In addition, Tenant shall comply with any reasonable plan adopted by Landlord which is designed to fulfill the requirements of any Applicable Laws, including ADA Requirements. 

Should compliance by Tenant with ADA Requirements under this Article 23 require Landlord’s consent under Article 8 of this Lease, Tenant
shall promptly seek such consent, provide the assurances and documents required by Article 8 and, following receipt of such consent, promptly comply with the provisions of Article 8 and ADA Requirements under this Article 23. 

If Tenant fails to comply with ADA Requirements as required in this paragraph, then, after reasonable notice to Tenant, Landlord may comply or
cause such compliance, in which case Tenant shall reimburse Landlord upon demand for Landlord’s reasonable costs incurred in effecting compliance. 

  
 32 

 ARTICLE 24 

LATE CHARGES 
 If
any installment of Rent or any other sum due from Tenant shall not be received when said amount is due, then Tenant shall pay to Landlord a late charge equal to five percent (5%) of the overdue amount plus any attorneys’ fees incurred by
Landlord by reason of Tenant’s failure to pay Rent and/or other charges when due hereunder. The late charge shall be deemed Additional Rent and the right to require it shall be in addition to all of Landlord’s other rights and remedies
hereunder or at law and shall not be construed as liquidated damages or as limiting Landlord’s remedies in any manner. In addition to the late charge described above, any Rent or other amounts owing hereunder which are not paid within ten
(10) days after the date they are due shall bear interest from the date when due until paid at a rate per annum equal to the lesser of (i) the annual “Bank Prime Loan” rate cited in the Federal Reserve Statistical Release
Publication G.13(415), published on the first Tuesday of each calendar month (or such other comparable index as Landlord and Tenant shall reasonably agree upon if such rate ceases to be published) plus two (2) percentage points, and
(ii) the highest rate permitted by applicable law. Notwithstanding the foregoing, in the first instance each calendar year wherein Tenant is late in making a payment to Landlord of Rent or any other sum payable by Tenant hereunder, the
foregoing late charge shall not be assessed until five (5) days after such Rent or other amount is past due. 
 ARTICLE 25

 LANDLORD’S RIGHT TO CURE DEFAULT; PAYMENTS BY TENANT 

25.1 Landlord’s Cure. All covenants and agreements to be kept or performed by Tenant under this Lease shall be performed by
Tenant, at Tenant’s sole cost and expense, and without any reduction of Rent, except to the extent, if any, otherwise expressly provided herein. If Tenant shall fail to perform any obligation under this Lease, and such failure shall continue in
excess of the time allowed under Section 19.1.2 above, unless a specific time period is otherwise stated in this Lease, Landlord may, but shall not be obligated to, make any such payment or perform any such act on Tenant’s part without
waiving its rights based upon any default of Tenant and without releasing Tenant from any obligations hereunder. 
 25.2 Tenant’s
Reimbursement. Except as may be specifically provided to the contrary in this Lease, Tenant shall pay to Landlord, upon delivery by Landlord to Tenant of statements therefor: (i) sums equal to expenditures reasonably made and
obligations incurred by Landlord in connection with the remedying by Landlord of Tenant’s defaults pursuant to the provisions of Section 25.1 above; (ii) sums equal to all Claims referred to in Article 10 of this Lease; and
(iii) sums equal to all expenditures made and obligations incurred by Landlord in collecting or attempting to collect the Rent or in enforcing or attempting to enforce any rights of Landlord under this Lease or pursuant to law, including,
without limitation, all legal fees and other amounts so expended and interest on all such sums from the date accrued by Landlord until paid by Tenant at a rate per annum equal to the lesser of ten percent (10%) or the maximum rate permitted by
law. Tenant’s obligations under this Section 25.2 shall survive the expiration or sooner termination of the Lease Term. 

ARTICLE 26 

ENTRY BY LANDLORD 

Landlord reserves the right at all reasonable times and upon reasonable notice to Tenant (which notice, notwithstanding anything to the
contrary contained within this Lease, may be oral, and which notice shall not be required in the case of an emergency) to enter the Premises to (i) inspect them; (ii) show the Premises to prospective purchasers, mortgagees or, during the
last year of the Lease Term, to prospective tenants, or to current or prospective mortgagees, ground or underlying lessors or insurers; (iii) post notices of non-responsibility; or (iv) alter, improve or repair the Premises or the
Building, or for structural alterations, repairs or improvements to the Building or the Building’s systems and equipment. Notwithstanding anything to the contrary contained in this Article 26, Landlord may enter the Premises at any time to
(A) perform services required of Landlord, including janitorial service; (B) take possession due to any Event of Default by Tenant in the manner provided herein; and (C) perform any covenants of Tenant which Tenant fails

  
 33 

 
to perform. Landlord may make any such entries without the abatement of Rent and may take such reasonable steps as required to accomplish the stated purposes. Except to the extent caused by
Landlord’s gross negligence or willful misconduct, Tenant hereby waives any claims for damages or for any injuries or inconvenience to or interference with Tenant’s business, lost profits, any loss of occupancy or quiet enjoyment of the
Premises, and any other loss occasioned thereby. For each of the above purposes, Landlord shall at all times have a key with which to unlock all the doors in the Premises, excluding Tenant’s vaults, safes and special security areas designated
in advance by Tenant in writing. In an emergency, Landlord shall have the right to use any means that Landlord may deem proper to open the doors in and to the Premises. Any entry into the Premises by Landlord in the manner hereinbefore described
shall not be deemed to be a forcible or unlawful entry into, or a detainer of, the Premises, or an actual or constructive eviction of Tenant from any portion of the Premises. No provision of this Lease shall be construed as obligating Landlord to
perform any repairs, alterations or decorations except as otherwise expressly agreed to be performed by Landlord herein. In connection with Landlord’s entry into the Premises pursuant to the terms of this Article 26, Landlord shall use
commercially reasonable efforts to minimize any material and adverse interference with Tenant’s business at the Premises. 

ARTICLE 27 

TENANT PARKING 

27.1 In General. Tenant shall rent from Landlord, commencing on the Lease Commencement Date, the number of parking spaces set
forth in Section 9 of the Summary, on a monthly basis throughout the Lease Term, which parking spaces shall pertain to the Project parking facility. Tenant shall pay to Landlord for such parking spaces on a monthly basis the prevailing rate
charged from time to time for the Project parking facility. In addition, Tenant shall be responsible for the full amount of any taxes imposed by any governmental authority in connection with the renting of such parking spaces by Tenant or the use of
the Project parking facility by Tenant. Tenant’s continued right to use the parking spaces is conditioned upon (i) Tenant abiding by all reasonable rules and regulations which are prescribed from time to time for the orderly operation and
use of the Project parking facility, including any sticker or other identification system established by Landlord, (ii) Tenant’s cooperation in seeing that Tenant’s employees and visitors also comply with such rules and regulations,
and (iii) no Event of Default of Tenant existing under this Lease. Tenant’s parking spaces shall be used only for parking of automobiles no larger than full size passenger automobiles, sport utility vehicles or pick-up trucks. The parking
spaces rented by Tenant pursuant to this Article 27 are provided to Tenant solely for use by Tenant’s own personnel and such rights may not be transferred, assigned, subleased or otherwise alienated by Tenant without Landlord’s prior
approval. Landlord specifically reserves the right to change the size, configuration, design, layout and all other aspects of the Project parking facility at any time and Tenant acknowledges and agrees that Landlord may, without incurring any
liability to Tenant and without any abatement of Rent under this Lease, from time to time, temporarily close-off or restrict access to the Project parking facility for purposes of permitting or facilitating any such construction, alteration or
improvements. Landlord may delegate its responsibilities hereunder relating to the Project parking facility to a parking operator in which case such parking operator shall have all the rights of control attributed hereby to the Landlord. Tenant may
validate visitor parking by such method or methods as the Landlord may establish, at the validation rate from time to time generally applicable to visitor parking. 

27.2 Parking Procedures. Landlord shall have no obligation to monitor the use of the Project parking facility, nor shall
Landlord be responsible for any loss or damage to any vehicle or other property or for any injury to any person. Tenant shall comply with all reasonable rules and regulations which may be adopted by Landlord from time to time with respect to parking
and/or the Project parking facility. Tenant shall not at any time use more parking spaces than the number so allocated (if any) to Tenant or park its vehicles or the vehicles of others in any portion of the Project not designated by Landlord for
Tenant’s parking. All trucks (other than pick-up trucks) and delivery vehicles shall be (i) parked at the loading dock of the Building, (ii) loaded and unloaded in a manner which does not unreasonably interfere with the businesses of
other occupants of the Building, and (iii) permitted to remain on the Project only so long as is reasonably necessary to complete loading and unloading. In the event Landlord elects in its sole and absolute discretion, or is required by any
law, to limit or control parking in the Building, whether by validation of parking tickets or any other method of assessment, Tenant agrees to participate in such validation or assessment program under such reasonable rules and regulations as are,
from time to time, established by Landlord. 

  
 34 

 ARTICLE 28 

MISCELLANEOUS PROVISIONS 

28.1 Terms; Captions. The words “Landlord” and “Tenant” as used herein shall include the plural as well as
the singular. The necessary grammatical changes required to make the provisions hereof apply either to corporations or partnerships or individuals, men or women, as the case may require, shall in all cases be assumed as though in each case fully
expressed. The captions of Articles and Sections are for convenience only and shall not be deemed to limit, construe, affect or alter the meaning of such Articles and Sections. 

28.2 Binding Effect. Subject to all other provisions of this Lease, each of the covenants, conditions and provisions of this
Lease shall extend to and shall, as the case may require, bind or inure to the benefit not only of Landlord and of Tenant, but also of their respective heirs, personal representatives, successors or assigns, provided this clause shall not permit any
assignment by Tenant contrary to the provisions of Article 14 of this Lease. 
 28.3 No Air Rights. No rights to any view or
to light or air over any property, whether belonging to Landlord or any other person, are granted to Tenant by this Lease. Under no circumstances whatsoever at any time during the Lease Term shall any temporary darkening of any windows of the
Premises or any temporary obstruction of the light or view therefrom by reason of any repairs, improvements, maintenance or cleaning in or about the Project, or any diminution, impairment or obstruction (whether partial or total) of light, air or
view by any structure which may be erected on any land comprising a part of, or located adjacent to or otherwise in the path of light, air or view to, the Project, in any way impose any liability upon Landlord or in any way reduce or diminish
Tenant’s obligations under this Lease. 
 28.4 Modification of Lease. Should any current or prospective mortgagee or
ground lessor for the Building or Project require a modification of this Lease, which modification will not materially and adversely change the rights and obligations of Tenant hereunder, then and in such event, Tenant agrees that this Lease may be
so modified and agrees to execute whatever documents are reasonably required therefor and to deliver the same to Landlord within ten (10) business days following a request therefor. 

28.5 Transfer of Landlord’s Interest. Tenant acknowledges that Landlord has the right to transfer all or any portion of its
interest in the Project or Building and in this Lease, and Tenant agrees that in the event of any such transfer, Landlord shall automatically be released from all liability under this Lease and Tenant agrees to look solely to such transferee for the
performance of Landlord’s obligations hereunder after the date of transfer and such transferee shall be deemed to have fully assumed and be liable for all obligations of this Lease to be performed by Landlord, including the return of any
Security Deposit, and Tenant shall attorn to such transferee. Tenant further acknowledges that Landlord may assign its interest in this Lease to a mortgage lender as additional security and agrees that such an assignment shall not release Tenant
from its obligations hereunder and that Tenant shall continue to look solely to Landlord for the performance of its obligations hereunder. 

28.6 Prohibition Against Recording. Except as provided in Section 28.4 of this Lease, neither this Lease, nor any
memorandum, affidavit or other writing with respect thereto, shall be recorded by Tenant or by anyone acting through, under or on behalf of Tenant. 

28.7 Landlord’s Title. Landlord’s title is and always shall be paramount to the title of Tenant. Nothing herein
contained shall empower Tenant to do any act which can, shall or may encumber the title of Landlord. 
 28.8 Relationship of
Parties. Nothing contained in this Lease shall be deemed or construed by the parties hereto or by any third party to create the relationship of principal and agent, partnership, joint venturer or any association between Landlord and Tenant.

 28.9 Application of Payments. Landlord shall have the right to apply payments received from Tenant pursuant to this Lease,
regardless of Tenant’s designation of such payments, to satisfy any obligations of Tenant hereunder, in such order and amounts as Landlord, in its sole discretion, may elect. 

  
 35 

 28.10 Time of Essence. Time is of the essence with respect to the performance of
every provision of this Lease in which time of performance is a factor, including, without limitation, the giving of any notice required to be given under this Lease or by law, the time periods for giving notice and the taking of any action with
respect to such notice. 
 28.11 Partial Invalidity. If any term, provision or condition contained in this Lease shall, to any
extent, be invalid or unenforceable, the remainder of this Lease, or the application of such term, provision or condition to persons or circumstances other than those with respect to which it is invalid or unenforceable, shall not be affected
thereby, and each and every other term, provision and condition of this Lease shall be valid and enforceable to the fullest extent possible permitted by law. 

28.12 No Warranty. In executing and delivering this Lease, Tenant has not relied on any representations, including, but not
limited to, any representation as to the amount of any item comprising Additional Rent or the amount of the Additional Rent in the aggregate or that Landlord is furnishing the same services to other tenants, at all, on the same level or on the same
basis, or any warranty or any statement of Landlord which is not set forth herein or in one or more of the exhibits attached hereto. 

28.13 Landlord Exculpation. The liability of Landlord or the Landlord Parties to Tenant for any default by Landlord under this
Lease or arising in connection herewith or with Landlord’s operation, management, leasing, repair, renovation, alteration or any other matter relating to the Project or the Premises shall be limited solely and exclusively to the lesser of
(a) the interest of Landlord in the Building or (b) the equity interest Landlord would have in the Building if the Building were encumbered by third-party debt in an amount equal to eighty percent (80%) of the value of the Building
(as such value is determined by Landlord). No natural person who is a principal, member, shareholder, employee, director, officer, investor, or partner of Landlord or of any of the Landlord Parties shall have any personal liability therefor, and
Tenant hereby expressly waives and releases such personal liability on behalf of itself and all persons claiming by, through or under Tenant. The limitations of liability contained in this Section 28.13 shall inure to the benefit of
Landlord’s and the Landlord Parties’ present and future partners, beneficiaries, officers, directors, trustees, shareholders, agents and employees, and their respective partners, heirs, successors and assigns. Under no circumstances shall
any present or future partner of Landlord (if Landlord is a partnership), or trustee or beneficiary (if Landlord or any partner of Landlord is a trust), have any liability for the performance of Landlord’s obligations under this Lease.
Notwithstanding any contrary provision herein, neither Landlord nor the Landlord Parties shall be liable under any circumstances for injury or damage to, or interference with, Tenant’s business, including but not limited to, loss of profits,
loss of rents or other revenues, loss of business opportunity, loss of goodwill or loss of use, in each case, however occurring. 
 28.14
Entire Agreement. It is understood and acknowledged that there are no oral agreements between the parties hereto affecting this Lease and this Lease (together with all Exhibits and Addenda hereto) constitutes the parties’ entire
agreement with respect to the leasing of the Premises and supersedes and cancels any and all previous negotiations, arrangements, brochures, agreements and understandings, if any, between the parties hereto or displayed by Landlord to Tenant with
respect to the subject matter thereof, and none thereof shall be used to interpret or construe this Lease. None of the terms, covenants, conditions or provisions of this Lease can be modified, deleted or added to except in writing signed by the
parties hereto. 
 28.15 Right to Lease. Landlord reserves the absolute right to effect such other tenancies in the Project as
Landlord in the exercise of its sole business judgment shall determine to best promote the interests of the Building or Project. Tenant does not rely on the fact, nor does Landlord represent, that any specific tenant or type or number of tenants
shall, during the Lease Term, occupy any space in the Building or Project. 
 28.16 Force Majeure. Except as otherwise
expressly provided herein, any prevention, delay or stoppage due to strikes, lockouts, labor disputes, acts of God, inability to obtain services, labor, or materials or reasonable substitutes therefor, governmental actions, civil commotions, fire or
other casualty, and other causes beyond the reasonable control of the party obligated to perform (collectively, a “Force Majeure”) shall excuse the performance of such party for a period equal to the length of any such prevention,
delay or stoppage and, therefore, if this Lease specifies a time period for performance of an obligation of either party, except as otherwise expressly provided herein, that time period shall be 

  
 36 

 
extended by the period of any delay in such party’s performance caused by an event of Force Majeure; provided however, that notwithstanding the foregoing, the obligations imposed with regard
to Rent and other charges to be paid by Tenant pursuant to this Lease, Tenant’s obligations pursuant to Article 5, Article 17, Article 18 and Article 23, and the time periods specified in Article 19 and in any provision of this Lease relating
to Tenant’s exercise of an option or a right hereunder, shall not be subject to extension due to an event of Force Majeure. 
 28.17
[Intentionally Deleted]. 
 28.18 Waiver of Redemption by Tenant. Tenant hereby waives, for Tenant and for all
those claiming under Tenant, any and all rights now or hereafter existing to redeem by order or judgment of any court or by any legal process or writ, Tenant’s right of occupancy of the Premises after any termination of this Lease. 

28.19 Notices. All notices, demands, statements, designations, approvals or other communications (collectively,
“Notices”) given or required to be given by either party to the other hereunder or by law shall be in writing, shall be (A) sent by United States certified or registered mail, postage prepaid, return receipt requested
(“Mail”), (B) transmitted by facsimile, if such facsimile is promptly followed by a Notice sent by Mail, (C) delivered by a nationally recognized overnight courier, or (D) delivered personally. Any Notice shall be
sent, transmitted, or delivered, as the case may be, to Tenant at the appropriate address set forth in Section 10 of the Summary, or to such other place as Tenant may from time to time designate in a Notice to Landlord, or to Landlord at the
appropriate address set forth in Section 11 of the Summary, or to such other place as Landlord may from time to time designate in a Notice to Tenant. Any Notice will be deemed given (i) three (3) days after the date it is posted if
sent by Mail, (ii) the date the facsimile is transmitted, (iii) the date the overnight courier delivery is made or such delivery is refused, or (iv) the date personal delivery is made or such delivery is refused. If Tenant is notified
of the identity and address of Landlord’s mortgagee or ground or underlying lessor, Tenant shall give to such mortgagee or ground or underlying lessor written notice of any default by Landlord under the terms of this Lease by registered or
certified mail, and such mortgagee or ground or underlying lessor shall be given a reasonable period of time to cure such default (but in no event less than sixty (60) days following receipt of such notice) prior to Tenant’s exercising any
remedy available to Tenant. 
 28.20 Joint and Several. If there is more than one Tenant, the obligations imposed upon Tenant
under this Lease shall be joint and several. 
 28.21 Authority. If Tenant is a corporation, trust or partnership, each
individual executing this Lease on behalf of Tenant hereby represents and warrants that Tenant is a duly formed and existing entity qualified to do business in California and that Tenant has full right and authority to execute and deliver this Lease
and that each person signing on behalf of Tenant is authorized to do so. In such event Tenant shall, within ten (10) days after execution of this Lease, deliver to Landlord satisfactory evidence of such authority and, if a corporation, upon
demand by Landlord, also deliver to Landlord satisfactory evidence of (i) good standing in Tenant’s state of incorporation and (ii) qualification to do business in California. 

28.22 Attorneys’ Fees. In the event that either Landlord or Tenant should bring suit for the possession of the Premises,
for the recovery of any sum due under this Lease, or because of the breach of any provision of this Lease or for any other relief against the other, then all costs and expenses, including reasonable attorneys’ fees, incurred by the prevailing
party therein shall be paid by the other party, which obligation on the part of the other party shall be deemed to have accrued on the date of the commencement of such action and shall be enforceable whether or not the action is prosecuted to
judgment. Without limiting the generality of the foregoing, if Landlord utilizes the services of an attorney for the purpose of collecting any Rent due and unpaid by Tenant or in connection with any other breach of this Lease by Tenant, Tenant
agrees to pay Landlord actual attorneys’ fees for such services, regardless of the fact that no legal action may be commenced or filed by Landlord. 

28.23 Governing Law; Waiver of Trial by Jury. This Lease shall be construed and enforced in accordance with the laws of the
State of California. IN ANY ACTION OR PROCEEDING ARISING HEREFROM, LANDLORD AND TENANT HEREBY CONSENT TO (I) THE JURISDICTION OF ANY COMPETENT COURT WITHIN THE STATE OF CALIFORNIA, (II) SERVICE OF PROCESS BY ANY MEANS AUTHORIZED BY CALIFORNIA
LAW, AND (III) IN THE INTEREST OF SAVING TIME AND EXPENSE, TRIAL WITHOUT A JURY IN ANY ACTION, 

  
 37 

 
PROCEEDING OR COUNTERCLAIM BROUGHT BY EITHER OF THE PARTIES HERETO AGAINST THE OTHER OR THEIR SUCCESSORS IN RESPECT OF ANY MATTER ARISING OUT OF OR IN CONNECTION WITH THIS LEASE, THE RELATIONSHIP
OF LANDLORD AND TENANT, TENANT’S USE OR OCCUPANCY OF THE PREMISES, AND/OR ANY CLAIM FOR INJURY OR DAMAGE, OR ANY EMERGENCY OR STATUTORY REMEDY. IN THE EVENT LANDLORD COMMENCES ANY SUMMARY PROCEEDINGS OR ACTION FOR NONPAYMENT OF BASE RENT OR
ADDITIONAL RENT, TENANT SHALL NOT INTERPOSE ANY COUNTERCLAIM OF ANY NATURE OR DESCRIPTION (UNLESS SUCH COUNTERCLAIM SHALL BE MANDATORY) IN ANY SUCH PROCEEDING OR ACTION, BUT SHALL BE RELEGATED TO AN INDEPENDENT ACTION AT LAW. 

28.24 Submission of Lease. Submission of this instrument for examination or signature by Tenant does not constitute a
reservation of, option for or option to lease, and it is not effective as a lease or otherwise until execution and delivery by both Landlord and Tenant. 

28.25 Brokers. Landlord and Tenant hereby warrant to each other that they have had no dealings with any real estate broker or
agent in connection with the negotiation of this Lease, excepting only the real estate brokers or agents specified in Section 12 of the Summary (the “Brokers”), and that they know of no other real estate broker or agent who is
entitled to a commission in connection with this Lease. Each party agrees to indemnify and defend the other party against and hold the other party harmless from any and all Claims with respect to any leasing commission or equivalent compensation
alleged to be owing on account of any dealings with any real estate broker or agent, other than the Brokers, occurring by, through, or under the indemnifying party. 

28.26 Independent Covenants. This Lease shall be construed as though the covenants herein between Landlord and Tenant are
independent and not dependent and Tenant hereby expressly waives the benefit of any statute to the contrary and agrees that, except as expressly set forth in Section 19.5, if Landlord fails to perform its obligations set forth herein, Tenant
shall not be entitled to make any repairs or perform any acts hereunder at Landlord’s expense or to any setoff of the Rent or other amounts owing hereunder against Landlord. 

28.27 Project or Building Name and Signage. Landlord shall have the right at any time to change the name of the Project or
Building and to install, affix and maintain any and all signs on the exterior and on the interior of the Project or Building as Landlord may, in Landlord’s sole discretion, desire. Tenant shall not use the name of the Project or Building or use
pictures or illustrations of the Project or Building in advertising or other publicity or for any purpose other than as the address of the business to be conducted by Tenant in the Premises, without the prior written consent of Landlord. 

28.28 Confidentiality. Tenant acknowledges that the financial terms and conditions of this Lease and any related documents are
confidential information. Tenant shall keep such confidential information strictly confidential and shall not disclose such confidential information to any person or entity other than Tenant’s employees, directors, financial, legal, and space
planning consultants, potential investors, and other Tenant advisors reasonably in need of such information, or as otherwise required by law (including but not limited to disclosure, if any, required under securities laws to the extent applicable to
Tenant). 
 28.29 Transportation Management. Tenant shall fully comply with all present or future programs intended to manage
parking, transportation or traffic in and around the Building, and in connection therewith, Tenant shall take responsible action for the transportation planning and management of all employees located at the Premises by working directly with
Landlord, any governmental transportation management organization or any other transportation-related committees or entities. 
 28.30
Building Renovations. It is specifically understood and agreed that, except as specifically set forth herein, Landlord has made no representation or warranty to Tenant and has no obligation and has made no promises to alter, remodel,
improve, renovate, repair or decorate the Premises, Building, or any part thereof and that no representations respecting the condition of the Premises or the Building have been made by Landlord to Tenant except as specifically set forth herein or in
the Tenant Work Letter. However, Tenant hereby acknowledges that Landlord may during the Lease Term renovate, improve, alter, or modify (collectively, the “Renovations”) the Project, the Building

  
 38 

 
and/or the Premises including without limitation the parking structure, common areas, systems and equipment, roof, and structural portions of the same, which Renovations may include, without
limitation, (i) installing sprinklers in the Building common areas and tenant spaces, (ii) modifying the common areas and tenant spaces to comply with Applicable Laws, including regulations relating to the physically disabled, seismic
conditions, and building safety and security, and (iii) installing new floor covering, lighting, and wall coverings in the Building common areas, and in connection with any Renovations, Landlord may, among other things, erect scaffolding or
other necessary structures in the Building, limit or eliminate access to portions of the Project, including portions of the common areas, or perform work in the Building, which work may create noise, dust or leave debris in the Building. Tenant
hereby agrees that such Renovations and Landlord’s actions in connection with such Renovations shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of Rent. Notwithstanding the foregoing, Landlord
shall use commercially reasonable efforts to minimize any interference with Tenant’s use of or access to the Premises in connection with any Renovations undertaken by Landlord. Landlord shall have no responsibility for, and shall not for any
reason be liable to Tenant for, any direct or indirect injury to or interference with Tenant’s business arising from the Renovations, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or
any part of the Premises or of Tenant’s personal property or improvements resulting from the Renovations or Landlord’s actions in connection with such Renovations, or for any inconvenience or annoyance occasioned by such Renovations or
Landlord’s actions. 
 28.31 No Violation. Tenant hereby warrants and represents that neither its execution of nor
performance under this Lease shall cause Tenant to be in violation of any agreement, instrument, contract, law, rule or regulation by which Tenant is bound, and Tenant shall protect, defend, indemnify and hold Landlord harmless against any Claims
arising from Tenant’s breach of this warranty and representation. 
 28.32 Communications and Computer Lines. Tenant
shall, in accordance with the terms and conditions hereof, have the right to install, maintain, replace, remove or use any electronic, fiber, phone and data cabling and communications or computer wires (collectively, the “Lines”) at
the Project in or serving the Premises, provided that (i) Tenant shall obtain Landlord’s prior written consent (which consent shall not be unreasonably withheld, conditioned or delayed), use an experienced and qualified contractor approved
in writing by Landlord, and comply with all of the other provisions of Article 7 and Article 8 of this Lease, (ii) an acceptable number of spare Lines and space for additional Lines shall be maintained for existing and future occupants of the
Project, as reasonably determined by Landlord, (iii) the Lines therefor (including riser cables) shall be appropriately insulated to prevent excessive electromagnetic fields or radiation, and shall be surrounded by a protective conduit
reasonably acceptable to Landlord, (iv) any new or existing Lines servicing the Premises shall comply with all Applicable Laws, (v) Tenant shall prior to the expiration of this Lease, at Tenant’s expense and in compliance with the
National Electric Code and other Applicable Laws, remove all Lines; provided, however, Tenant shall not remove such Lines if Tenant receives a written notice from Landlord at least fifteen (15) days prior to the expiration of the Lease
authorizing such Lines to remain in place, in which event the Lines shall be surrendered with the Premises upon the expiration or earlier termination of this Lease, and (vi) Tenant shall pay all costs in connection therewith. Landlord reserves
the right to require that Tenant remove any Lines located in or serving the Premises which are installed in violation of these provisions, or which are at any time in violation of any Applicable Laws or represent a dangerous or potentially dangerous
condition. Landlord further reserves the right to require that Tenant remove any and all lines located in or serving the Premises upon the expiration or earlier termination of this Lease. In the event that Tenant desires access to the Building
risers in connection with the exercise of its rights pursuant to this paragraph, then Tenant shall be required to utilize the services of Landlord’s designated Building riser management company. 

28.33 Office and Communications Services. 

28.33.1 The Provider. Landlord has advised Tenant that certain office and communications services may be offered to tenants of
the Building by a concessionaire under contract to Landlord (“Provider”). Tenant shall be permitted, in Tenant’s sole discretion, to contract with Provider for the provision of any or all of such services on such terms and
conditions as Tenant and Provider may agree. The current Providers are AT&T and Capital Communications. 
 28.33.2 Other
Terms. Tenant acknowledges and agrees that: (i) Landlord has made no warranty or representation to Tenant with respect to the availability of any such services, or the quality, reliability or

  
 39 

 
suitability thereof; (ii) the Provider is not acting as the agent or representative of Landlord in the provision of such services, and Landlord shall have no liability or responsibility for
any failure or inadequacy of such services, or any equipment or facilities used in the furnishing thereof, or any act or omission of Provider, or its agents, employees, representatives, officers or contractors; (iii) Landlord shall have no
responsibility or liability for the installation, alteration, repair, maintenance, furnishing, operation, adjustment or removal of any such services, equipment or facilities; and (iv) any contract or other agreement between Tenant and Provider
shall be independent of this Lease, the obligations of Tenant hereunder, and the rights of Landlord hereunder, and, without limiting the foregoing, no default or failure of Provider with respect to any such services, equipment or facilities, or
under any contract or agreement relating thereto, shall have any effect on this Lease or give to Tenant any offset or defense to the full and timely performance of its obligations hereunder, or entitle Tenant to any abatement of rent or additional
rent or any other payment required to be made by Tenant hereunder, or constitute any accrual or constructive eviction of Tenant, or otherwise give rise to any other claim of any nature against Landlord. 

28.34 Substitution of Other Premises. Intentionally Deleted. 

28.35 OFAC Compliance. 

28.35.1 Tenant represents and warrants that (a) Tenant and each person or entity owning an interest in Tenant is (i) not currently
identified on the Specially Designated Nationals and Blocked Persons List maintained by the Office of Foreign Assets Control, Department of the Treasury (“OFAC”) and/or on any other similar list maintained by OFAC pursuant to any
authorizing statute, executive order or regulation (collectively, the “List”), and (ii) not a person or entity with whom a citizen of the United States is prohibited to engage in transactions by any trade embargo, economic
sanction, or other prohibition of United States law, regulation, or Executive Order of the President of the United States, (b) none of the funds or other assets of Tenant constitute property of, or are beneficially owned, directly or
indirectly, by any Embargoed Person (as hereinafter defined), (c) no Embargoed Person has any interest of any nature whatsoever in Tenant (whether directly or indirectly), (d) none of the funds of Tenant have been derived from any unlawful
activity with the result that the investment in Tenant is prohibited by law or that the Lease is in violation of law, and (e) Tenant has implemented procedures, and will consistently apply those procedures, to ensure the foregoing
representations and warranties remain true and correct at all times. The term “Embargoed Person” means any person, entity or government subject to trade restrictions under U.S. law, including but not limited to, the International
Emergency Economic Powers Act, 50 U.S.C. §1701 et seq., The Trading with the Enemy Act, 50 U.S.C. App. 1 et seq., and any Executive Orders or regulations promulgated thereunder with the result that the investment in Tenant is prohibited by law
or Tenant is in violation of law. 
 28.35.2 Tenant covenants and agrees (i) to comply with all requirements of law relating to money
laundering, anti-terrorism, trade embargos and economic sanctions, now or hereafter in effect, (ii) to immediately notify Landlord in writing if any of the representations, warranties or covenants set forth in this paragraph or the preceding
paragraph are no longer true or have been breached or if Tenant has a reasonable basis to believe that they may no longer be true or have been breached, (iii) not to use funds from any “Prohibited Person” (as such term is defined in
the September 24, 2001 Executive Order Blocking Property and Prohibiting Transactions With Persons Who Commit, Threaten to Commit, or Support Terrorism) to make any payment due to Landlord under the Lease and (iv) at the request of
Landlord, to provide such information as may be requested by Landlord to determine Tenant’s compliance with the terms hereof. 

28.35.3 Tenant hereby acknowledges and agrees that Tenant’s inclusion on the List at any time during the Lease Term shall be a default of
the Lease. Notwithstanding anything herein to the contrary, Tenant shall not permit the Premises or any portion thereof to be used or occupied by any person or entity on the List or by any Embargoed Person (on a permanent, temporary or transient
basis), and any such use or occupancy of the Premises by any such person or entity shall be a default of the Lease. Simultaneously with the execution of the Lease, Tenant will provide to Landlord the names of the persons holding an ownership
interest in Tenant, for purposes of compliance with Presidential Executive Order 13224 (issued September 24, 2001). 
 [SIGNATURES ON
NEXT PAGE] 

  
 40 

 IN WITNESS WHEREOF, Landlord and Tenant have caused this Lease to be executed the day and date
first above written. 
  

					
	“Landlord”:
	
	 150 SPEAR STREET, LLC,
 a Delaware
limited liability company

		
	By:	 	 Principal Real Estate Investors, LLC,

a Delaware limited liability company

			
		 	By:	 	 /s/ Robert T. Klinkner

		 	Name:	 	 Robert T. Klinkner

		 	Its:	 	 Assistant Managing Director - Asset

		 		 	 Management

			
		 	By:	 	 /s/ Jay Fisher

		 	Name:	 	 Jay Fisher

		 	Its:	 	 Investment Director - Asset

		 		 	 Management

		
	“Tenant”:	 	
	
	 FORRESTER RESEARCH, INC.,
 a
Delaware corporation

		
	By:	 	 /s/ Michael A. Doyle

	Name:	 	 Michael A. Doyle

	Its:	 	 Chief Financial Officer

		
	By:	 	 /s/ Gail S. Mann

	Name:	 	 Gail S. Mann

	Its:	 	 Chief Legal Officer

 **If Tenant is a corporation, the authorized officers must sign on behalf of the corporation and indicate the capacity
in which they are signing. The document must be executed by the chairman of the board, president or vice-president, and the secretary, assistant secretary, chief financial officer or any assistant treasurer, unless the bylaws or a resolution
of the board of directors shall otherwise provide, in which event, the bylaws or a certified copy of the resolution, as the case may be, must be attached to this document.** 

  
 41 

 EXHIBIT A 
  

 
  
  

  
 EXHIBIT A 

1 

 EXHIBIT B 

150 SPEAR STREET, SAN FRANCISCO, CALIFORNIA 

TENANT WORK LETTER 
 This
Tenant Work Letter (“Tenant Work Letter”) shall set forth the terms and conditions relating to the construction of the Premises. All references in this Tenant Work Letter to the “Lease” shall mean the relevant portions of
the Lease to which this Tenant Work Letter is attached as Exhibit B. 
 SECTION 1 

AS-IS CONDITION 

Tenant hereby accepts the base, shell and core (i) of the Premises and (ii) of the floor(s) of the Building on which the Premises
are located (collectively, the “Base, Shell and Core”), in its current “AS-IS” condition existing as of the date of the Lease and the Lease Commencement Date. Except for the Tenant Improvement Allowance set forth
below and Landlord’s obligations pursuant to Article 23 of the Lease, Landlord shall not be obligated to make or pay for any alterations or improvements to the Premises, the Building or the Project. 

SECTION 2 

TENANT IMPROVEMENTS 

2.1 Tenant Improvement Allowance. Tenant shall be entitled to a one-time tenant improvement allowance (the “Tenant Improvement
Allowance”) in the amount of up to, but not exceeding $60.00 per rentable square foot of the Premises (i.e., up to $933,600 based on 15,560 rentable square feet of the Premises), for the costs relating to the initial design and
construction of Tenant’s improvements which are permanently affixed to the Premises (the “Tenant Improvements”), including, without limitation, space planning and design, construction fees, and architectural and consultant
fees; provided, however, that Landlord shall have no obligation to disburse all or any portion of the Tenant Improvement Allowance to Tenant unless Tenant makes a request for disbursement pursuant to the terms and conditions of
Section 2.2 below prior to that date which is six (6) months after the Lease Commencement Date. In no event shall Landlord be obligated to make disbursements pursuant to this Tenant Work Letter in a total amount which exceeds the
Tenant Improvement Allowance. Tenant shall not be entitled to receive any cash payment or credit against Rent or otherwise for any unused portion of the Tenant Improvement Allowance which is not used to pay for the Tenant Improvement Allowance Items
(as such term is defined below). 
 2.2 Disbursement of the Tenant Improvement Allowance. 

2.2.1 Tenant Improvement Allowance Items. Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance
shall be disbursed by Landlord only for the following items and costs (collectively, the “Tenant Improvement Allowance Items”): 

2.2.1.1 payment of the fees of the “Architect” and the “Engineers”, as those terms are defined in Section 3.1
of this Tenant Work Letter and payment of the fees incurred by, and the cost of documents and materials supplied by, Landlord and Landlord’s consultants in connection with the preparation and review of the “Construction Drawings”, as
that term is defined in Section 3.1 of this Tenant Work Letter; 
 2.2.1.2 the payment of plan check, permit and license fees
relating to construction of the Tenant Improvements; 

  
 EXHIBIT B 

1 

 2.2.1.3 the cost of construction of the Tenant Improvements, including, without limitation,
contractors’ fees and general conditions, testing and inspection costs, costs of utilities, trash removal and parking and hoists. 

2.2.1.4 the cost of any changes in the Base, Shell and Core work when such changes are required by the Construction Drawings (including if
such changes are due to the fact that such work is prepared on an unoccupied basis), such cost to include all direct architectural and/or engineering fees and expenses incurred in connection therewith; 

2.2.1.5 the cost of any changes to the Construction Drawings or Tenant Improvements required by applicable laws; 

2.2.1.6 sales and use taxes and Title 24 fees; 

2.2.1.7 the “Coordination Fee”, as that term is defined in Section 4.2.2.2 of this Tenant Work Letter; and 

2.2.1.8 all other costs to be expended by Landlord in connection with the construction of the Tenant Improvements. 

2.2.2 Disbursement of Tenant Improvement Allowance. Subject to Section 2.1 above, during the construction of the Tenant
Improvements, Landlord shall make disbursements of the Tenant Improvement Allowance for Tenant Improvement Allowance Items for the benefit of Tenant and shall authorize the release of monies for the benefit of Tenant as follows: 

2.2.2.1 Disbursements. From time to time during the construction of the Tenant Improvements (but no more frequently than monthly),
Tenant shall deliver to Landlord: (i) a request for payment of the “Contractor”, as that term is defined in Section 4.1 below, approved by Tenant, in a form to be provided by Landlord, showing the schedule, by trade, of
percentage of completion of the Tenant Improvements in the Premises, detailing the portion of the work completed and the portion not completed, and demonstrating that the relationship between the cost of the work completed and the cost of the work
to be completed complies with the terms of the “Final Costs Statement”, as that term is defined in Section 4.2.1 below; (ii) invoices from all of “Tenant’s Agents”, as that term is defined in
Section 4.1.2 below, for labor rendered and materials delivered to the Premises; (iii) executed conditional mechanic’s lien releases from all of Tenant’s Agents which shall comply with the applicable provisions of
California Civil Code Section 3262(d); and (iv) each of the general disbursement items referenced in Section 2.2.2.3 below, and all other information reasonably requested by Landlord. Tenant’s request for payment shall be
deemed Tenant’s acceptance and approval of the work furnished and/or the materials supplied as set forth in Tenant’s payment request. Within thirty (30) days of Landlord’s receipt of a completed disbursement request submission,
Landlord shall deliver a check to Tenant made jointly payable to Contractor and Tenant in payment of the lesser of (A) the amounts so requested by Tenant, as set forth in this Section 2.2.2.1, above, less a ten percent
(10%) retention (the aggregate amount of such retentions to be known as the “Final Retention”) and (B) the balance of any remaining available portion of the Tenant Improvement Allowance (not including the Final Retention),
provided that Landlord does not dispute any request for payment based on non-compliance of any work with the “Approved Working Drawings”, as that term is defined in Section 3.4 below, or due to any substandard work.
Landlord’s payment of such amounts shall not be deemed Landlord’s approval or acceptance of the work furnished or materials supplied as set forth in Tenant’s payment request. 

2.2.2.2 Final Retention. Subject to the provisions of this Tenant Work Letter, a check for the Final Retention payable jointly to
Tenant and Contractor shall be delivered by Landlord to Tenant following the completion of construction of the Premises, provided that (i) Tenant delivers to Landlord properly executed and fully unconditional mechanics lien releases in
compliance with both California Civil Code Section 3262(d)(2) and either Section 3262(d)(3) or Section 3262(d)(4), and (ii) Landlord has determined that no substandard work exists which adversely affects the mechanical,
electrical, plumbing, heating, ventilating and air conditioning, life-safety or other systems of the Building, the curtain wall of the Building, the structure or exterior appearance of the Building, or any other tenant’s use of such other
tenant’s leased premises in the Building, which determination shall be made promptly 

  
 EXHIBIT B 

2 

 
after the completion of construction, (iii) Tenant has delivered to Landlord a certificate of occupancy or permit cards signed off by the City with respect to the Premises; (iv) Tenant
has delivered to the Office of the Building as-built plans and City-permitted plans for the Tenant Improvements; (v) Tenant has delivered to the Office of the Building operation manuals and warranties for equipment included within the Tenant
Improvements, if applicable, and (vi) Tenant has delivered to Landlord each of the general disbursement items referenced in Section 2.2.2.3 below. The check for the Final Retention shall be delivered by Landlord to Tenant within
thirty (30) days of the satisfaction of the foregoing conditions. 
 2.2.2.3 General Disbursement Requirements. In addition to
the disbursement requirements referenced above, Tenant acknowledges and agrees that the following items are required as a condition to any disbursement of the Tenant Improvement Allowance: 

 

	 	•	 	Copy of contract with Tenant’s General Contractor 

  

	 	•	 	Copy of General Contractor’s certificate of insurance, including Additional Insured endorsement naming Landlord and Landlord’s property manager as Additional Insureds 

 

	 	•	 	General Contractor’s Schedule of Values, showing total contract value 

 2.2.2.4 Other
Terms. Landlord shall only be obligated to make disbursements from the Tenant Improvement Allowance to the extent costs are incurred by Tenant for Tenant Improvement Allowance Items. 

2.3 Standard Tenant Improvement Package. Landlord has established specifications (the “Building Standard Tenant
Improvements”) for the Building standard components to be used in the construction of the Tenant Improvements in the Premises, a copy of which has been delivered to Tenant. The quality of Tenant Improvements shall be equal to or of greater
quality than the quality of the Building Standard Tenant Improvements, provided that Landlord may, at Landlord’s option, require the Tenant Improvements to comply with certain Building Standard Tenant Improvements. Landlord may make changes to
the Specifications from time to time. 
 2.4 Removal of Non Building Standard Tenant Improvements. “Non Standard Tenant
Improvements” shall mean (a) any part of the Tenant Improvements which do not constitute Building Standard Tenant Improvements, including, but not limited to, plumbing and millwork; (b) any changes in or additions to the Tenant
Improvements made at the request of Tenant or due to any other act or omission on the part of Tenant; and (c) a configuration of the Tenant Improvements which is not usual and customary for normal occupancy. If so directed by Landlord prior to
the end of the Term of this Lease, Tenant shall pay Landlord the cost to remove from the Premises any Non Standard Tenant Improvements designated by Landlord, and shall replace such designated Non Standard Tenant Improvements to be removed with
Building Standard Tenant Improvements. Notwithstanding the foregoing, in the event that Tenant’s request for approval any Tenant Improvement shall request a designation by Landlord of any removal obligation in accordance with the terms hereof,
then Landlord shall indicate any such removal obligation at the time of Landlord’s consent. If Tenant makes such a request and Landlord shall not indicate in its approval that the applicable Tenant Improvement will be required to be removed by
Tenant, then the applicable Tenant Improvement will not be required to be removed. 
 SECTION 3 

CONSTRUCTION DRAWINGS 

3.1 Selection of Architect/Construction Drawings. Tenant shall retain the architect/space planner (the “Architect”)
approved by Landlord, which approval shall not be unreasonably withheld, to prepare the Construction Drawings. Landlord hereby approves Margulies-Peruzzi Architects (Boston) and Hooks ASD (SF), collectively, as the Architect. Tenant shall retain the
engineering consultants reasonably designated by Landlord (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC,

  
 EXHIBIT B 

3 

 
life safety, and sprinkler work in the Premises. The plans and drawings to be prepared by Architect and the Engineers hereunder shall be known collectively as the “Construction
Drawings”. All Construction Drawings shall comply with the drawing format and specifications reasonably determined by Landlord, and shall be subject to Landlord’s approval, which shall not be unreasonably withheld, conditioned or
delayed. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the base building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no
responsibility in connection therewith. Landlord’s review of the Construction Drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to
review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Construction Drawings are reviewed by Landlord or its space planner, architect, engineers and consultants, and notwithstanding any
advice or assistance which may be rendered to Tenant by Landlord or Landlord’s space planner, architect, engineers, and consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any
omissions or errors contained in the Construction Drawings. 
 3.2 Final Space Plan. Tenant shall supply Landlord with four
(4) copies signed by Tenant of its final space plan for the Premises before any architectural working drawings or engineering drawings have been commenced. The final space plan (the “Final Space Plan”) shall include a layout
and designation of all offices, rooms and other partitioning, their intended use, and equipment to be contained therein. Landlord may request clarification or more specific drawings for special use items not included in the Final Space Plan.
Landlord shall advise Tenant within five (5) business days after Landlord’s receipt of the Final Space Plan for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall promptly
(i) cause the Final Space Plan to be revised to correct any deficiencies or other matters Landlord may reasonably require, and (ii) deliver such revised Final Space Plan to Landlord. 

3.3 Final Working Drawings. After the Final Space Plan has been approved by Landlord and Tenant, Tenant shall promptly cause the
Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and cause the Architect to compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a
form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits for the Tenant Improvements (collectively, the “Final Working Drawings”), and shall submit the same to Landlord for
Landlord’s approval. Tenant shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings. Landlord shall advise Tenant within five (5) business days after Landlord’s receipt of the Final Working
Drawings for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall promptly (i) revise the Final Working Drawings in accordance with such review and any disapproval of Landlord in
connection therewith, and (ii) deliver such revised Final Working Drawings to Landlord. 
 3.4 Approved Working Drawings. The
Final Working Drawings shall be approved by Landlord (the “Approved Working Drawings”) prior to the commencement of construction of the Premises by Tenant. After approval by Landlord of the Final Working Drawings, Tenant shall
promptly submit the same to the appropriate governmental authorities for all applicable building permits. Tenant hereby agrees that neither Landlord nor Landlord’s consultants shall be responsible for obtaining any building permit or
certificate of occupancy for the Premises and that obtaining the same shall be Tenant’s responsibility; provided, however, that Landlord shall cooperate with Tenant in executing permit applications and performing other ministerial
acts reasonably necessary to enable Tenant to obtain any such permit or certificate of occupancy. No changes, modifications or alterations in the Approved Working Drawings may be made without the prior written consent of Landlord, which consent
shall not be unreasonably withheld, conditioned or delayed. 
 SECTION 4 

CONSTRUCTION OF THE TENANT IMPROVEMENTS 

4.1 Tenant’s Selection of Contractor and Tenant’s Agents. 

4.1.1 The Contractor. A general contractor shall be retained by Tenant to construct the Tenant Improvements. Such general contractor
(“Contractor”) shall be selected by Tenant from a list of general contractors supplied by Landlord, and Tenant shall deliver to Landlord notice of its selection of the Contractor upon such selection. Landlord hereby agrees that TCB
Builders, Inc., shall be the Contractor. 

  
 EXHIBIT B 

4 

 4.1.2 Tenant’s Agents. In connection with the Tenant Improvements, Tenant shall be
permitted to use all architects, engineers, project managers, subcontractors, mechanics and materialmen and other consultants selected by TCB Builders, Inc. (and, together with the Contractor, collectively, “Tenant’s Agents”).
Tenant shall provide Landlord with a list of all Tenant’s Agents prior to commencement of any construction in the Premises. All Tenant’s Agents shall utilize union labor in compliance with the master labor agreements existing between trade
unions and the local chapter of the Associated General Contractors of America and each such Tenant Agents shall be a reputable, licensed company doing business in San Francisco, California. Notwithstanding anything to the contrary contained herein,
in the event that Tenant desires access to the Building risers in connection with the Tenant Improvements, then Tenant shall be required to utilize the services of Landlord’s designated Building riser management company. 

4.2 Construction of Tenant Improvements by Tenant’s Agents. 

4.2.1 Construction Contract; Cost Budget. Prior to Tenant’s execution of the construction contract and general conditions with
Contractor (the “Contract”), Tenant shall submit the Contract to Landlord for its approval, which approval shall not be unreasonably withheld or delayed. Prior to the commencement of the construction of the Tenant Improvements, and
after Tenant has accepted all bids for the Tenant Improvements, Tenant shall provide Landlord with a written detailed cost breakdown (the “Final Costs Statement”), by trade, of the final costs to be incurred, or which have been
incurred, as set forth more particularly in Section 2.2.1.1 through 2.2.1.8 above, in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (which
costs form a basis for the amount of the Contract, if any (the “Final Costs”). To the extent the Final Costs exceed the Tenant Improvement Allowance (less any portion thereof already disbursed by Landlord, or in the process of being
disbursed by Landlord, on or before the commencement of construction of the Tenant Improvements), Tenant shall make payments for such additional costs (the “Over-Allowance Amount”) out of its own funds, but Tenant shall provide
Landlord with the documents described in Sections 2.2.2.1 (i), (ii), (iii) and (iv) above, for Landlord’s approval, prior to Tenant paying such costs. The Over-Allowance Amount shall be paid by Tenant prior
to the disbursement by Landlord of any of the then remaining portion of the Tenant Improvement Allowance. In the event that, after the Final Costs have been delivered by Landlord to Tenant, the costs relating to the design and construction of the
Tenant Improvements shall change, any additional costs necessary for such design and construction in excess of the Final Costs shall, to the extent they exceed the remaining balance of the Tenant Improvement Allowance, be paid by Tenant prior to the
commencement of the construction of such changes out of its own funds, but Tenant shall continue to provide Landlord with the documents described in Sections 2.2.2.1 (i), (ii), (iii) and (iv) above, for
Landlord’s approval, prior to Tenant paying such costs. 
 4.2.2 Tenant’s Agents. 

4.2.2.1 Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work. Tenant’s and Tenant’s
Agents’ construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant and Tenant’s Agents shall not,
in any way, unreasonably interfere with, obstruct, or delay, the work of Landlord’s base building contractor and subcontractors with respect to the Base, Shell and Core or any other work in the Building; (iii) Tenant’s Agents shall
submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and
Tenant’s Agents shall adhere to such corrected schedule; and (iv) Tenant shall abide by all reasonable rules made by Landlord’s Building contractor or Landlord’s Building manager with respect to the use of freight, loading dock
and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.

 4.2.2.2 Coordination Fee. Tenant shall pay a logistical coordination fee (the “Coordination Fee”) to Landlord in
an amount equal to the product of (i) two and one-half percent (2.5%), and (ii) the total cost of constructing the Tenant Improvements (excluding any “soft” costs such as Architect and Engineer fees and project management), which
Coordination Fee shall be for services relating to the coordination of the construction of the Tenant 

  
 EXHIBIT B 

5 

 
Improvements. In the event the Architect is not licensed in California and Landlord deems it necessary to review Tenant’s plans and drawings to review code compliance and permitting issues,
then in addition to the Coordination Fee and other amounts payable by Tenant hereunder, Tenant shall reimburse Landlord for amounts paid by Landlord for the review of Tenant’s plans and drawings as referenced in Section 3 above, which
amounts shall be charged against the Tenant Improvement Allowance. 
 4.2.2.3 Indemnity. Tenant’s indemnity of Landlord as set
forth in the Lease shall also apply with respect to any and all costs, losses, damages, injuries and liabilities related in any way to any act or omission of Tenant or Tenant’s Agents, or anyone directly or indirectly employed by any of them,
or in connection with Tenant’s non-payment of any amount arising out of the Tenant Improvements and/or Tenant’s disapproval of all or any portion of any request for payment. Such indemnity by Tenant, as set forth in the Lease, shall also
apply with respect to any and all costs, losses, damages, injuries and liabilities related in any way to Landlord’s performance of any ministerial acts reasonably necessary (i) to permit Tenant to complete the Tenant Improvements, and
(ii) to enable Tenant to obtain any building permit or certificate of occupancy for the Premises. 
 4.2.2.4 Insurance
Requirements. 
 4.2.2.4.1 General Coverages. All of Tenant’s Agents shall carry worker’s compensation insurance
covering all of their respective employees, and shall also carry public liability insurance, including property damage, all with limits, in form and with companies as are required to be carried by Tenant as set forth in the Lease. 

4.2.2.4.2 Special Coverages. Tenant shall carry “Builder’s All Risk” insurance in an amount approved by Landlord
covering the construction of the Tenant Improvements, and such other insurance as Landlord may require, it being understood and agreed that the Tenant Improvements shall be insured by Tenant pursuant to the Lease immediately upon completion thereof.
Such insurance shall be in amounts and shall include such extended coverage endorsements as may be reasonably required by Landlord, and in form and with companies as are required to be carried by Tenant as set forth in the Lease. 

4.2.2.4.3 General Terms. Certificates for all insurance carried pursuant to this Section 4.2.2.4 shall be delivered to
Landlord before the commencement of construction of the Tenant Improvements and before the Contractor’s equipment is moved onto the site. All such policies of insurance must contain a provision that the company writing said policy will give
Landlord thirty (30) days prior written notice of any cancellation or lapse of the effective date or any reduction in the amounts of such insurance. In the event that the Tenant Improvements are damaged by any cause during the course of the
construction thereof, Tenant shall immediately repair the same at Tenant’s sole cost and expense. All policies carried under this Section 4.2.2.4 shall insure Landlord and Tenant, as their interests may appear, as well as Contractor
and Tenant’s Agents, and shall name as additional insureds Landlord’s Property Manager, Landlord’s Asset Manager, and all mortgagees and ground lessors of the Building. All insurance, except Workers’ Compensation, maintained by
Tenant’s Agents shall preclude subrogation claims by the insurer against anyone insured thereunder. Such insurance shall provide that it is primary insurance as respects the owner and that any other insurance maintained by owner is excess and
noncontributing with the insurance required hereunder. The requirements for the foregoing insurance shall not derogate from the provisions for indemnification of Landlord by Tenant under Section 4.2.2.3 of this Tenant Work Letter. 

4.2.3 Governmental Compliance. The Tenant Improvements shall comply in all respects with the following: (i) the Code and other
state, federal, city or quasi-governmental laws, codes, ordinances and regulations, as each may apply according to the rulings of the controlling public official, agent or other person; (ii) applicable standards of the American Insurance
Association (formerly, the National Board of Fire Underwriters) and the National Electrical Code; and (iii) building material manufacturer’s specifications. 

4.2.4 Inspection by Landlord. Landlord shall have the right to inspect the Tenant Improvements at all times, provided however,
that Landlord’s failure to inspect the Tenant Improvements shall in no event constitute a waiver of any of Landlord’s rights hereunder nor shall Landlord’s inspection of the Tenant Improvements constitute Landlord’s approval of
the same. Should Landlord disapprove any portion of the Tenant Improvements, Landlord shall 

  
 EXHIBIT B 

6 

 
notify Tenant in writing of such disapproval and shall specify the items disapproved. Any defects or deviations in, and/or reasonable disapproval by Landlord of, the Tenant Improvements shall be
rectified by Tenant at no expense to Landlord, provided however, that in the event Landlord reasonably determines that a defect or deviation exists or reasonably disapproves of any matter in connection with any portion of the Tenant
Improvements and such defect, deviation or matter might adversely affect the mechanical, electrical, plumbing, heating, ventilating and air conditioning or life-safety systems of the Building, the structure or exterior appearance of the Building or
any other tenant’s use of such other tenant’s leased premises, Landlord may, take such action as Landlord reasonably deems necessary, at Tenant’s expense and without incurring any liability on Landlord’s part, to correct any such
defect, deviation and/or matter, including, without limitation, causing the cessation of performance of the construction of the Tenant Improvements until such time as the defect, deviation and/or matter is corrected to Landlord’s satisfaction.

 4.2.5 Meetings. Commencing upon the execution of the Lease, Tenant shall hold weekly meetings at a reasonable time, with the
Architect and the Contractor regarding the progress of the preparation of Construction Drawings and the construction of the Tenant Improvements, which meetings shall be held in the Building or at another location designated by Landlord and
reasonably acceptable to Tenant, and Landlord and/or its agents shall receive prior notice of, and shall have the right to attend, all such meetings, and, upon Landlord’s request, certain of Tenant’s Agents shall attend such meetings. In
addition, minutes shall be taken at all such meetings, a copy of which minutes shall be promptly delivered to Landlord. One such meeting each month shall include the review of Contractor’s current request for payment. 

4.3 Notice of Completion; Copy of “As Built” Plans. Within ten (10) days after completion of construction of the Tenant
Improvements, Tenant shall cause a Notice of Completion to be recorded in the office of the Recorder of the County in which the Building is located in accordance with Section 3093 of the Civil Code of the State of California or any successor
statute, and shall furnish a copy thereof to Landlord upon such recordation. If Tenant fails to do so, Landlord may execute and file the same on behalf of Tenant as Tenant’s agent for such purpose, at Tenant’s sole cost and expense. At the
conclusion of construction, (i) Tenant shall cause the Architect and Contractor (A) to update the Approved Working Drawings as necessary to reflect all changes made to the Approved Working Drawings during the course of construction,
(B) to certify to the best of their knowledge that the “record-set” of as-built drawings are true and correct, which certification shall survive the expiration or termination of the Lease, and (C) to deliver to Landlord two
(2) computer discs containing the Approved Working Drawings in AutoCAD format, and (ii) Tenant shall deliver to Landlord two (2) copies of all warranties, guaranties, and operating manuals and information relating to the improvements,
equipment, and systems in the Premises. 
 4.4 Coordination by Tenant’s Agents with Landlord. Upon Tenant’s delivery of the
Contract to Landlord under Section 4.2.1 of this Tenant Work Letter, Tenant shall furnish Landlord with a schedule setting forth the projected date of the completion of the Tenant Improvements and showing the critical time deadlines for
each phase, item or trade relating to the construction of the Tenant Improvements. 
 SECTION 5 

MISCELLANEOUS 
 5.1
Tenant’s Representative. Tenant has designated Jean Baranowski as its sole representative with respect to the matters set forth in this Tenant Work Letter, who shall have full authority and responsibility to act on behalf of the Tenant
as required in this Tenant Work Letter. 
 5.2 Landlord’s Representative. Landlord has designated Jim Osburn as its sole
representative with respect to the matters set forth in this Tenant Work Letter, who, until further notice to Tenant, shall have full authority and responsibility to act on behalf of the Landlord as required in this Tenant Work Letter. 

5.3 Time of the Essence in This Tenant Work Letter. Unless otherwise indicated, all references herein to a “number of days”
shall mean and refer to calendar days. If any item requiring approval is timely disapproved by Landlord, the procedure for preparation of the document and approval thereof shall be repeated until the document is approved by Landlord. 

  
 EXHIBIT B 

7 

 5.4 Tenant’s Lease Default. Notwithstanding any provision to the contrary contained
in the Lease, if an event of default by Tenant of this Tenant Work Letter (which, for purposes hereof, shall include, without limitation, the delivery by Tenant to Landlord of any oral or written notice that Tenant does not intend to occupy the
Premises, and/or any other anticipatory breach of the Lease) or an Event of Default under the Lease has occurred at any time on or before the substantial completion of the Premises, then (i) in addition to all other rights and remedies granted
to Landlord pursuant to the Lease, at law and/or in equity, Landlord shall have the right to withhold payment of all or any portion of the Tenant Improvement Allowance and/or Landlord may cause Contractor to cease the construction of the Premises
(in which case, Tenant shall be responsible for any delay in the substantial completion of the Premises caused by such work stoppage), and (ii) all other obligations of Landlord under the terms of this Tenant Work Letter shall be forgiven until
such time as such default is cured pursuant to the terms of the Lease (in which case, Tenant shall be responsible for any delay in the substantial completion of the Premises caused by such inaction by Landlord). In addition, if the Lease is
terminated prior to the Lease Commencement Date, for any reason due to an Event of Default by Tenant as described in Section 19.1 of the Lease or under this Tenant Work Letter (including, without limitation, any anticipatory breach
described above in this Section 5.4), then (A) Tenant shall be liable to Landlord for all damages available to Landlord pursuant to the Lease and otherwise available to Landlord at law and/or in equity by reason of a default by
Tenant under the Lease or this Tenant Work Letter (including, without limitation, the remedies available to Landlord pursuant to California Civil Code Section 1951.2), and (B) Tenant shall pay to Landlord, as Additional Rent under the
Lease, within thirty (30) days of receipt of a statement therefor, together with reasonable back-up documentation, any and all costs (if any) incurred by Landlord (including any portion of the Tenant Improvement Allowance disbursed by Landlord)
and not reimbursed or otherwise paid by Tenant through the date of such termination in connection with the Tenant Improvements to the extent planned, installed and/or constructed as of such date of termination, including, but not limited to, any
costs related to the removal of all or any portion of the Tenant Improvements and restoration costs related thereto. For purposes of calculating the damages available to Landlord under California Civil Code 1951.2, the Lease Commencement Date shall
be deemed to be the date which the Lease Commencement Date would have otherwise occurred but for such default by Tenant. 

  
 EXHIBIT B 

8 

 EXHIBIT C 

150 SPEAR STREET, SAN FRANCISCO, CALIFORNIA 

NOTICE OF LEASE TERM DATES 
  

							
	To:	 	  
	 		 	
		 	  
	 		 	
		 	  
	 		 	
		 	  
	 		 	

  

	 	Re:	Office Lease dated             , 2010 between
                    , a                     
(“Landlord”), and                     , a
                     (“Tenant”) concerning Suite              on
floor(s)                      of the office building located at
                    , San Francisco, California. 

Gentlemen: 
 In accordance with the
above-referenced Office Lease (the “Lease”), we wish to advise you and/or confirm as follows: 
  

	 	1.	The Lease Term shall commence on or has commenced on             ,          for a term of
                     ending on             ,
        . 

  

	 	2.	Rent commenced to accrue on                      in the amount of
$            . 

  

	 	3.	If the Lease Commencement Date is other than the first day of the month, the first billing will contain a pro rata adjustment. Each billing thereafter, with the exception of the final billing, shall be for the full
amount of the monthly installment as provided for in the Lease. 

  

	 	4.	Your rent checks should be made payable to                      at
                    . 

  

	 	5.	The approximate number of rentable square feet within the Premises is                     
(        ) square feet. 

  

	 	6.	Tenant’s Share as adjusted based upon the approximate number of rentable square feet within the Premises is             %. 

Agreed to and Accepted 
 as of
            , 2010. 
  

							
	“Tenant”:	 		 	
		
	  
	 	,
	a	 	  

							
		
	By:	 	  

		 	 Its:
	 	  

  
 EXHIBIT C 

1 

 Exhibit D 

150 SPEAR STREET, SAN FRANCISCO, CALIFORNIA 

RULES AND REGULATIONS 

Tenant shall faithfully observe and comply with the following Rules and Regulations. Landlord shall not be responsible to Tenant for the
nonperformance of any of said Rules and Regulations by or otherwise with respect to the acts or omissions of any other tenants or occupants of the Project. In the event of any conflict between the Rules and Regulations and the other provisions of
this Lease, the latter shall control. 
 Tenant shall not alter any lock or install any new or additional locks or bolts on any doors or
windows of the Premises without obtaining Landlord’s prior written consent. Tenant shall bear the cost of any lock changes or repairs required by Tenant. Two keys will be furnished by Landlord for the Premises, and any additional keys required
by Tenant must be obtained from Landlord at a reasonable cost to be established by Landlord. Upon the termination of this Lease, Tenant shall restore to Landlord all keys of stores, offices, and toilet rooms, either furnished to, or otherwise
procured by, Tenant and in the event of the loss of keys so furnished, Tenant shall pay to Landlord the reasonable cost of replacing same or of changing the lock or locks opened by such lost key if Landlord shall deem it necessary to make such
changes. 
 All doors opening to public corridors shall be kept closed at all times except for normal ingress and egress to the Premises.

 Landlord reserves the right to close and keep locked all entrance and exit doors of the Building during such hours as are customary for
comparable buildings in the San Francisco, California area. Tenant, its employees and agents must be sure that the doors to the Building are securely closed and locked when leaving the Premises if it is after the normal hours of business for the
Building. Any tenant, its employees, agents or any other persons entering or leaving the Building at any time when it is so locked, or any time when it is considered to be after normal business hours for the Building, may be required to sign the
Building register. Access to the Building may be refused unless the person seeking access has proper identification or has a previously arranged pass for access to the Building. Landlord will furnish passes to persons for whom Tenant requests same
in writing. Tenant shall be responsible for all persons for whom Tenant requests passes and shall be liable to Landlord for all acts of such persons. Landlord and Landlord’s agents shall in no case be liable for damages for any error with
regard to the admission to or exclusion from the Building of any person. In case of invasion, mob, riot, public excitement, or other commotion, Landlord reserves the right to prevent access to the Building or the Project during the continuance
thereof by any means it deems appropriate for the safety and protection of life and property. 
 No furniture, freight or equipment of any
kind shall be brought into the Building without prior notice to Landlord. All moving activity into or out of the Building shall be scheduled with Landlord and done only at such time and in such manner as Landlord designates. Landlord shall have the
right to prescribe the weight, size and position of all safes and other heavy property brought into the Building and also the times and manner of moving the same in and out of the Building. Safes and other heavy objects shall, if considered
necessary by Landlord, stand on supports of such thickness as is necessary to properly distribute the weight. Landlord will not be responsible for loss of or damage to any such safe or property in any case. Any damage to any part of the Building,
its contents, occupants or visitors by moving or maintaining any such safe or other property shall be the sole responsibility and expense of Tenant. 

No furniture, packages, supplies, equipment or merchandise will be received in the Building or carried up or down in the elevators, except
between such hours, in such specific elevator and by such personnel as shall be reasonably designated by Landlord. 
 The requirements of
Tenant will be attended to only upon application at the management office for the Project or at such office location designated by Landlord. Employees of Landlord shall not perform any work or do anything outside their regular duties unless under
special instructions from Landlord. 

  
 EXHIBIT D 

1 

 No sign, advertisement, notice or handbill shall be exhibited, distributed, painted or affixed by
Tenant on any part of the Premises or the Building without the prior written consent of the Landlord. Tenant shall not disturb, solicit, peddle, or canvass any occupant of the Project and shall cooperate with Landlord and Landlord’s agents to
prevent same. 
 The toilet rooms, urinals, wash bowls and other apparatus shall not be used for any purpose other than that for which they
were constructed, and no foreign substance of any kind whatsoever shall be thrown therein. The expense of any breakage, stoppage or damage resulting from the violation of this rule shall be borne by the tenant who, or whose servants, employees,
agents, visitors or licensees shall have caused same. 
 Tenant shall not overload the floor of the Premises, nor mark, drive nails or
screws, or drill into the partitions, woodwork or drywall or in any way deface the Premises or any part thereof without Landlord’s prior written consent. Tenant shall not purchase spring water, ice, towel, linen, maintenance or other like
services from any person or persons not approved by Landlord, which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall approve a sufficient number of sources of such services to provide Tenant with a reasonable
selection, but only in such instances and to such extent as Landlord in its judgment shall consider consistent with the security and proper operation of the Building. 

Except for vending machines intended for the sole use of Tenant’s employees and invitees, no vending machine or machines other than
fractional horsepower office machines shall be installed, maintained or operated upon the Premises without the written consent of Landlord. 

Tenant shall not use or keep in or on the Premises, the Building, or the Project any kerosene, gasoline, explosive material, corrosive
material, material capable of emitting toxic fumes, or other inflammable or combustible fluid chemical, substitute or material. Tenant shall provide material safety data sheets for any Hazardous Material used or kept on the Premises. 

Tenant shall not without the prior written consent of Landlord use any method of heating or air conditioning other than that supplied by
Landlord. 
 Tenant shall not use, keep or permit to be used or kept, any foul or noxious gas or substance in or on the Premises, or permit
or allow the Premises to be occupied or used in a manner offensive or reasonably objectionable to Landlord or other occupants of the Project by reason of noise, odors, or vibrations, or interfere with other tenants or those having business therein,
whether by the use of any musical instrument, radio, phonograph, or in any other way. Tenant shall not throw anything out of doors, windows or skylights or down passageways. 

Tenant shall not bring into or keep within the Project, the Building or the Premises any animals, birds, aquariums, or, except in areas
designated by Landlord, bicycles or other vehicles. 
 No cooking shall be done or permitted on the Premises, nor shall the Premises be used
for the storage of merchandise, for lodging or for any improper, objectionable or immoral purposes. Notwithstanding the foregoing, Underwriters’ laboratory-approved equipment and microwave ovens may be used in the Premises for heating food and
brewing coffee, tea, hot chocolate and similar beverages for employees and visitors, provided that such use is in accordance with all applicable federal, state, county and city laws, codes, ordinances, rules and regulations. 

The Premises shall not be used for manufacturing or for the storage of merchandise except as such storage may be incidental to the use of the
Premises provided for in the Summary. Tenant shall not occupy or permit any portion of the Premises to be occupied as an office for a messenger-type operation or dispatch office, public stenographer or typist, or for the manufacture or sale of
liquor, narcotics, or tobacco in any form, or as a medical office, or as a barber or manicure shop, or as an employment bureau without the express prior written consent of Landlord. Tenant shall not engage or pay any employees on the Premises except
those actually working for such tenant on the Premises nor advertise for laborers giving an address at the Premises. 

  
 EXHIBIT D 

2 

 Landlord reserves the right to exclude or expel from the Project any person who, in the
reasonable judgment of Landlord, is intoxicated or under the influence of liquor or drugs, or who shall in any manner do any act in violation of any of these Rules and Regulations. 

Tenant, its employees and agents shall not loiter in or on the entrances, corridors, sidewalks, lobbies, courts, halls, stairways, elevators,
vestibules or any Common Areas for the purpose of smoking tobacco products or for any other purpose, nor in any way obstruct such areas, and shall use them only as a means of ingress and egress for the Premises. 

Tenant shall not waste electricity, water or air conditioning and agrees to cooperate fully with Landlord to ensure the most effective
operation of the Building’s heating and air conditioning system, and shall refrain from attempting to adjust any controls. Tenant shall participate in recycling programs undertaken by Landlord. 

Tenant shall store all its trash and garbage within the interior of the Premises. No material shall be placed in the trash boxes or
receptacles if such material is of such nature that it may not be disposed of in the ordinary and customary manner of removing and disposing of trash and garbage in San Francisco, California without violation of any law or ordinance governing such
disposal. All trash, garbage and refuse disposal shall be made only through entry-ways and elevators provided for such purposes at such times as Landlord shall designate. If the Premises is or becomes infested with vermin as a result of the use or
any misuse or neglect of the Premises by Tenant, its agents, servants, employees, contractors, visitors or licensees, Tenant shall forthwith, at Tenant’s expense, cause the Premises to be exterminated from time to time to the reasonable
satisfaction of Landlord and shall employ such licensed exterminators as shall be approved in writing in advance by Landlord. 
 Tenant
shall comply with all safety, fire protection and evacuation procedures and regulations established by Landlord or any governmental agency. 

Any persons employed by Tenant to do janitorial work shall be subject to the prior written approval of Landlord, and while in the Building and
outside of the Premises, shall be subject to and under the control and direction of the Building manager (but not as an agent or servant of such manager or of Landlord), and Tenant shall be responsible for all acts of such persons. 

No awnings or other projection shall be attached to the outside walls of the Building without the prior written consent of Landlord, and no
curtains, blinds, shades or screens shall be attached to or hung in, or used in connection with, any window or door of the Premises other than Landlord standard drapes. All electrical ceiling fixtures hung in the Premises or spaces along the
perimeter of the Building must be fluorescent and/or of a quality, type, design and a warm white bulb color approved in advance in writing by Landlord. Neither the interior nor exterior of any windows shall be coated or otherwise sunscreened without
the prior written consent of Landlord. Tenant shall be responsible for any damage to the window film on the exterior windows of the Premises and shall promptly repair any such damage at Tenant’s sole cost and expense. Tenant shall keep its
window coverings closed during any period of the day when the sun is shining directly on the windows of the Premises. Prior to leaving the Premises for the day, Tenant shall draw or lower window coverings and extinguish all lights. Tenant shall
abide by Landlord’s regulations concerning the opening and closing of window coverings which are attached to the windows in the Premises, if any, which have a view of any interior portion of the Building or Building common areas. 

The sashes, sash doors, skylights, windows, and doors that reflect or admit light and air into the halls, passageways or other public places
in the Building shall not be covered or obstructed by Tenant, nor shall any bottles, parcels or other articles be placed on the windowsills. 

Tenant must comply with reasonable requests by the Landlord concerning the informing of their employees of items of importance to the
Landlord. 
 Tenant must comply with all applicable “NO-SMOKING” or similar ordinances. If Tenant is required under the
ordinance to adopt a written smoking policy, a copy of said policy shall be on file in the office of the Building. 

  
 EXHIBIT D 

3 

 Tenant hereby acknowledges that Landlord shall have no obligation to provide guard service or
other security measures for the benefit of the Premises, the Building or the Project. Tenant hereby assumes all responsibility for the protection of Tenant and its agents, employees, contractors, invitees and guests, and the property thereof, from
acts of third parties, including keeping doors locked and other means of entry to the Premises closed, whether or not Landlord, at its option, elects to provide security protection for the Project or any portion thereof. Tenant further assumes the
risk that any safety and security devices, services and programs which Landlord elects, in its sole discretion, to provide may not be effective, or may malfunction or be circumvented by an unauthorized third party, and Tenant shall, in addition to
its other insurance obligations under this Lease, obtain its own insurance coverage to the extent Tenant desires protection against losses related to such occurrences. Tenant shall cooperate in any reasonable safety or security program developed by
Landlord or required by law. 
 All office equipment of any electrical or mechanical nature shall be placed by Tenant in the Premises in
settings approved by Landlord, to absorb or prevent any vibration, noise and annoyance. 
 Tenant shall not use in any space or in the
public halls of the Building, any hand trucks except those equipped with rubber tires and rubber side guards. 
 No on-site auction,
liquidation, fire sale, going-out-of-business or bankruptcy sale shall be conducted in the Premises without the prior written consent of Landlord. 

No tenant shall use or permit the use of any portion of the Premises for living quarters, sleeping apartments or lodging rooms. 

Tenant shall install and maintain, at Tenant’s sole cost and expense, an adequate, visibly marked and properly operational fire
extinguisher next to any duplicating or photocopying machines or similar heat producing equipment, which may or may not contain combustible material, in the Premises. 

Landlord reserves the right at any time to change or rescind any one or more of these Rules and Regulations, or to make such other and further
reasonable Rules and Regulations as in Landlord’s judgment may from time to time be necessary for the management, safety, care and cleanliness of the Premises, Building, the Common Areas and the Project, and for the preservation of good order
therein, as well as for the convenience of other occupants and tenants therein. Landlord may waive any one or more of these Rules and Regulations for the benefit of any particular tenants, but no such waiver by Landlord shall be construed as a
waiver of such Rules and Regulations in favor of any other tenant, nor prevent Landlord from thereafter enforcing any such Rules or Regulations against any or all tenants of the Project. Tenant shall be deemed to have read these Rules and
Regulations and to have agreed to abide by them as a condition of its occupancy of the Premises. 

  
 EXHIBIT D 

4 

 EXHIBIT E 

150 SPEAR STREET, SAN FRANCISCO, CALIFORNIA 

SITE PLAN SHOWING CORRIDORS ON 11TH FLOOR 

 
 

 

  
 EXHIBIT E 

1 

 ADDENDUM 1 

RIGHT OF FIRST OFFER 
 This Addendum 1
(“Addendum 1”) is incorporated as a part of that certain Office Lease dated November 24, 2010 (the “Lease”), by and between 150 Spear Street, LLC, a Delaware limited liability company
(“Landlord”), and Forrester Research, Inc., a Delaware corporation (“Tenant”), for the Premises located at 150 Spear Street, San Francisco, California, Suite 1100 (the “Premises”). Any capitalized
terms used herein and not otherwise defined herein shall have the meaning ascribed to such terms as set forth in the Lease. 
 1. Right of First
Offer. During the period commencing on the Lease Commencement Date and expiring on November 1, 2012, Tenant shall have a one-time (not recurring) unencumbered right of first offer (“ROFO”) to lease (a) all but not
less than all of those certain premises consisting of approximately 3,476 rentable square feet and known as Suite 1050 (the “Suite 1050 ROFO Space”) and (b) no less than 7,780 rentable square feet (in the area shown on
Schedule 1 to Addendum 1 attached hereto) of those certain premises consisting of approximately 12,085 rentable square feet and known as Suite 1000 (the “Suite 1000 ROFO Space” and together with the Suite 1050 ROFO Space,
collectively, the “ROFO Spaces”), which may become available for lease. 
 2. Procedure for Acceptance. Upon any portion of
the ROFO Space becoming available for lease by Tenant, Landlord shall give Tenant written notice (the “ROFO Notice”) that such ROFO Space will or has become available for lease by Tenant. Landlord shall endeavor to give Tenant a
ROFO Notice (a) nine (9) months prior to the anticipated date of availability with respect to the Suite 1000 ROFO Space, and (b) six (6) months prior to the anticipated date of availability with respect to the Suite 1050 ROFO
Space. On or before the date which is fifteen (15) business days after Tenant’s receipt of Landlord’s ROFO Notice (the “Election Date”), Tenant shall deliver written notice to Landlord (“Tenant’s Election
Notice”) pursuant to which Tenant shall have the right to elect either to: (i) lease the entire ROFO Space (subject to Tenant’s right to lease no less than 7,780 rentable square feet of the Suite 1000 ROFO Space) identified in
Landlord’s ROFO Notice upon the terms set forth in this Addendum 1; or (ii) refuse to lease such ROFO Space. If Tenant does not respond in writing to Landlord’s ROFO Notice by the Election Date, Tenant shall be deemed to have elected
not to lease the ROFO Space identified in Landlord’s ROFO Notice. If Tenant elects or is deemed to have elected not to lease such ROFO Space, then Tenant’s ROFO with respect to the ROFO Space identified in Landlords’ ROFO Notice shall
terminate and Landlord shall thereafter have the right to lease all or any portion of such ROFO Space to anyone to whom Landlord desires on any terms Landlord desires. Except to the extent expressly provided herein to the contrary, Tenant must elect
to exercise its ROFO provided herein, if at all, with respect to all of the space offered by Landlord to Tenant in Landlord’s ROFO Notice at any particular time, and Tenant may not elect to lease only a portion thereof. 

3. Lease of ROFO Space. If Tenant timely exercises its ROFO as set forth herein, Tenant shall provide Landlord a non-refundable deposit,
equivalent to the last one (1) month’s Base Rent and Operating Expenses for the ROFO Space identified in the ROFO Notice and the parties shall have ten (10) business days after Landlord receives Tenant’s Election Notice and
deposit from Tenant in which to execute an amendment to the Lease adding such ROFO Space to the Premises on all of the terms and conditions as applicable to the original Premises; provided, that (a) the Base Rent for the ROFO Space shall be at
the Fair Market Rental Rate as of the commencement of Tenant’s lease of the ROFO Space, determined in accordance with Section 2.2.3 of the Lease and (b) Landlord shall deliver to Tenant possession of the ROFO Space in its then
existing condition and state of repair, “AS IS”, without any obligation of Landlord to remodel, improve or alter the ROFO Space, to perform any other construction or work of improvement upon the ROFO Space, but Landlord shall provide
Tenant with an improvement allowance in an amount equal to One Dollar ($1.00) per rentable square foot of ROFO Space per month of the Term applicable to such ROFO Spaces that Tenant will be obligated to pay rent, which allowance shall be reduced by
One Dollar ($1.00) for each month (or portion thereof) between the Lease Commencement Date and the date of Tenant’s Election Notice. Tenant acknowledges that no representations or warranties of any kind, express or implied, respecting the
condition of the ROFO Space, Building, or Project have been made by Landlord or any agent of Landlord to Tenant. Tenant further acknowledges that neither Landlord nor any of Landlord’s agents, representatives or employees has made any
representations as to the suitability or fitness of the ROFO 

  
 ADDENDUM 1 

1 

 
Space for the conduct of Tenant’s business, or for any other purpose. Any exception to the foregoing provisions must be made by express written agreement signed by both parties. Upon full
execution of an amendment for the subject ROFO Space, the non-refundable deposit shall be credited toward the Base Rent for such ROFO Space, as agreed between the parties. 

4. Limitations on, and Conditions to, ROFO. Notwithstanding anything in the foregoing to the contrary, at Landlord’s option, and in
addition to all of Landlord’s remedies under the Lease, at law or in equity, the ROFO hereinabove granted to Tenant shall not be deemed to be properly exercised if any of the following individual events occur or any combination thereof occur:
(a) an Event of Default has occurred at any time during the Lease Term; and/or (b) on the scheduled commencement date for Tenant’s lease of the ROFO Space identified in Landlord’s ROFO Notice, an Event of Default exists under the
Lease; and/or (c) Tenant has assigned its rights and obligations under the Lease (except in connection with a Permitted Transfer) or Tenant has subleased more than twenty five percent (25%) of the rentable area of the Premises (except in
connection with a Permitted Transfer); and/or (d) Tenant’s financial condition at the time Tenant’s Election Notice is delivered to Landlord is inadequate, in Landlord’s reasonable judgment, to satisfy Tenant’s obligations
under this Lease; and/or (e) Tenant has failed to exercise properly this ROFO in a timely manner in strict accordance with the provisions of this Addendum 1; and/or (f) Tenant no longer has possession of all or any part of the Premises
under the Lease (other than in connection with any Permitted Transfer or a sublease of less than twenty-five percent (25%) of the rentable area of the Premises), or if the Lease has been terminated earlier, pursuant to the terms and provisions
of the Lease. Tenant’s ROFO to lease the ROFO Space is personal to the original Tenant executing the Lease (and any transferee pursuant to a Permitted Transfer), and may not be assigned or exercised, voluntarily or involuntarily, by or to, any
person or entity other than the original Tenant, and shall only be available to and exercisable by the Tenant when the original Tenant is in actual and physical possession of the entire Premises. 

  
 ADDENDUM 1 

2 

 SCHEDULE 1 TO ADDENDUM 1 

SUITE 1000 ROFO SPACE 
  

 

  
 ADDENDUM 1 

3 

 ADDENDUM 2 

ROOFTOP SPACE ADDENDUM 
 THIS ROOFTOP
SPACE ADDENDUM (“Rooftop Space Addendum”) is made and entered into by and between 150 SPEAR STREET, LLC, a Delaware limited liability company (“Landlord”) and FORRESTER RESEARCH, INC., a Delaware corporation
(“Tenant”), and is dated as of the date of the Office Lease (“Lease”) by and between Landlord and Tenant to which this Rooftop Space Addendum is attached. The agreements set forth in this Rooftop Space Addendum
shall have the same force and effect as if set forth in the Lease. To the extent the terms of this Rooftop Space Addendum are inconsistent with the terms of the Lease, the terms of this Rooftop Space Addendum shall control. All capitalized terms
used herein and not otherwise defined shall have the meanings set forth in the Lease. 
 1. Right to Install Rooftop Equipment. During the
Lease Term, and, subject to Tenant’s compliance with all Applicable Laws and covenants, conditions and restrictions, and Landlord’s prior review and approval of plans and specifications for all such installation, Tenant and Tenant’s
contractors (which shall first be reasonably approved by Landlord) shall have the right to access, install, replace, remove, operate and maintain, subject to the terms of Article 8 of the Lease and this Rooftop Space Addendum, a microwave
dish not exceeding two (2) feet in diameter (the “Antenna”) on the rooftop of the Building at the location more specifically shown on the diagram attached hereto as Schedule 1 to Addendum 2 (or if no location is shown on
Schedule 1 to Addendum 2, at a location reasonably determined by Landlord), including the cabling and connecting equipment (collectively, the “Connecting Equipment”). The Antenna and the Connecting Equipment are collectively
referred to as the “Rooftop Equipment”. 
 2. Fee. In consideration for Tenant’s right to install and operate the
Rooftop Equipment as set forth in this Rooftop Space Addendum, Tenant shall pay to Landlord, from and after the date the Rooftop Equipment is installed, a monthly amount payable in advance on the first
(1st) day of each month, equal to the sum of $500.00. Such amount for any partial month shall be prorated based on the number of days in such partial month. Notwithstanding the foregoing, no
fee under this Section 2 shall be payable by Tenant with respect to an Antenna solely for receiving DirectTV® or similar satellite television service. In lieu of Tenant’s right to install the Rooftop Equipment as provided
herein, Tenant may elect to tie-in to service provided by Landlord’s existing microwave and/or satellite dish. In such event, Tenant’s tie-in to, and use of, Landlord’s existing service shall be subject to all of the terms, covenants
and conditions of the Lease and Tenant shall pay to Landlord, together with payment of Base Rent, a fee of $100.00 per month for such service. 
 3.
Conditioned Upon Lease. This Rooftop Space Addendum is contingent upon the Lease being in effect and compliance by Tenant with all of the terms and provisions hereof. If the Lease terminates or expires for any reason, Tenant’s
rights under this Rooftop Space Addendum shall also terminate concurrently therewith unless otherwise agreed in writing by Landlord in its sole and absolute discretion. 

4. No Assignment. Notwithstanding anything to the contrary set forth in Article 14 of the Lease Tenant’s rights under this Rooftop
Space Addendum may not be assigned, transferred to or used by any other person or entity except in connection with a Permitted Transfer. 
 5.
Installation. Tenant’s installation and operation of the Rooftop Equipment shall be governed by the following terms and conditions: 

a. Installation shall be conducted by licensed contractors approved by Landlord. No roof penetrations shall permitted. 

  
 ADDENDUM 2 

1 

 b. All plans and specifications for the Rooftop Equipment shall be subject to Landlord’s
prior review and approval and the prior review and approval of all other tenants or occupants of the Building maintaining or operating rooftop equipment and related equipment at the Building. Upon Landlord’s request, Tenant shall prepare and
submit a detailed set of plans and specifications for the proposed Rooftop Equipment, methods of installation and proposed locations thereof to all tenants and occupants having a right to review Tenant’s proposed Rooftop Equipment. 

c. Tenant, at Tenant’s sole cost and expense, shall be responsible for any modifications to the rooftop, risers, utility areas or other
facilities or portions of the Building which may be necessary to accommodate the Rooftop Equipment. 
 d. It is expressly understood that
Landlord retains the right to use the roof of the Building for any purpose whatsoever (including granting rights to third parties to utilize any portion of the roof not utilized by Tenant). 

e. For the purposes of determining Tenant’s obligations with respect to its use of the roof of the Building herein provided, all of the
provisions of the Lease relating to compliance with requirements as to insurance, indemnity, and compliance with Applicable Laws shall apply to the installation, use and maintenance of the Rooftop Equipment. Landlord shall not have any obligations
with respect to the Rooftop Equipment. Landlord makes no representation that the Rooftop Equipment will function properly and Tenant agrees that Landlord shall not be liable to Tenant therefor. 

f. Tenant shall (i) be solely responsible for any damage caused as a result of the Rooftop Equipment, (ii) promptly pay any tax,
license or permit fees charged pursuant to any Applicable Laws in connection with the installation, maintenance or use of the Rooftop Equipment and comply with all Applicable Laws pertaining to the use of the Rooftop Equipment, and (iii) pay
for all necessary repairs, replacements to or maintenance of the Rooftop Equipment. 
 g. To the extent not installed by Tenant in
accordance with the terms and conditions of the Tenant Work Letter, the installation of the Rooftop Equipment shall constitute alterations and shall be performed in accordance with and subject to the provisions of Article 8 of the Lease,
including, without limitation, Tenant’s obligation to obtain Landlord’s prior consent to the size and other specifications of the Rooftop Equipment, which consent shall not be unreasonably withheld, conditioned or delayed. 

6. Design Considerations. 
 a. All
Rooftop Equipment shall be properly screened from view for aesthetic reasons, and must not be visible from street level. 
 b. The Antenna
may not protrude above a height equal to the highest point of the Building structure. 
 c. Tenant, at Tenant’s sole cost and expense,
shall install and maintain such fencing and other protective equipment and/or visual screening on or about the Rooftop Equipment as Landlord may reasonably determine. 

d. The Rooftop Equipment shall be clearly marked to show the name, address, telephone number of the person to contact in case of emergency.

 e. The Rooftop Equipment must be properly secured and installed so as not to be affected by high winds or other elements. 

f. The weight of the Rooftop Equipment shall not exceed the load limits of the Building. 

  
 ADDENDUM 2 

2 

 7. Compliance with Laws. Tenant’s rights set forth in this Rooftop Space Addendum shall be
subject to all Applicable Laws. Landlord makes no representation that any such Laws permit such installation and operation, and Tenant shall be solely responsible to determine the feasibility and legality of installing the Rooftop Equipment. Without
limiting the generality of the foregoing, if any testing, sampling or disclosures relating to rooftop equipment at the Building are required to satisfy OSHA or other governmental agencies (including for radio frequency [RF] or electromagnetic field
[EMF] emissions), Tenant shall pay the costs of any such required tests and studies (or its prorata share thereof if the cost is properly shared by other rooftop users). Landlord shall have no liability or responsibility for the maintenance or
compliance with laws of any towers, antennas or structures, including, without limitation, compliance with Part 17 of the Federal Communications Commissions’ Rules. 

8. No Interference.  
 a.
The Rooftop Equipment and operations shall not interfere with the communications configurations, frequencies or operating equipment of any existing users on the rooftop (collectively, “Existing Users”), including any equipment which
the Existing Users have the right to install or operate but have not yet installed. Further, the Rooftop Equipment and operations shall comply with all non-interference rules of the Federal Communications Commission (“FCC”). Upon
receipt of written notice of apparent interference by Tenant with Existing Users, Tenant shall have the responsibility to promptly terminate such interference or to demonstrate with competent information that the apparent interference in fact is not
caused by Tenant’s Rooftop Equipment or operations. Subsequent to the date Tenant commences the operation of the Rooftop Equipment, Landlord shall not knowingly install or permit the installation of new equipment at the Building if such new
equipment is likely to cause interference with the operation of the Rooftop Equipment, it being acknowledged that Landlord shall have no right or responsibility to prevent the installation of equipment any party has the right to install under the
terms of its lease or occupancy agreement, or pursuant to applicable laws or regulations. With respect to equipment which the installing party has no right to install, Landlord shall require the installing party to first provide Tenant with notice
of the equipment to be installed and Tenant shall then have the reasonable opportunity to meet with the party wishing to install the additional equipment so that any potential interference can be resolved to the satisfaction of Tenant. If in the
future equipment is installed at the Building which interferes with the operation of the Rooftop Equipment, Tenant agrees to reasonably cooperate with such other user to resolve such interference in a mutually acceptable manner, subject to and in
accordance with the rules of the FCC and the terms of any rights of Existing Users to operate new or revised equipment at the Building. Notwithstanding anything to the contrary herein, in no event shall Landlord have any liability with respect to
interference with Tenant’s operations or any loss of business or profits, and Tenant’s sole remedy in the event of a breach of this provision shall be to pursue an action for injunctive relief. 

b. In no event shall the Antenna or any Connecting Equipment damage or adversely affect or interfere with the normal operation of the Building
(including, but not limited to mechanical, electrical, life-safety, structural systems, window washing or other maintenance functions of the Building). Tenant hereby agrees to indemnify, defend and hold Landlord harmless from and against any and all
claims, costs, damages, expenses and liabilities (including reasonable attorneys’ fees) arising out of Tenant’s failure to comply with the provisions of this Rooftop Space Addendum, provided that Tenant’s indemnification obligation
hereunder shall not apply to the extent same is caused by the gross negligence or willful misconduct of Landlord or its employees, agents or contractors. Should the use of the Rooftop Equipment by Tenant interfere with systems of the Building or
telecommunications systems of any tenant, Tenant shall make such adjustments to the Rooftop Equipment or its related equipment as may be reasonably required by Landlord. 

9. Access. Subject to the terms of this Rooftop Space Addendum, Tenant shall have the right to access its Rooftop Equipment during the hours of
the Building more particularly set forth in Section 6.1.1 of the Lease. In exercising its right of access to the roof, Tenant agrees to cooperate and comply with any reasonable security procedures, access requirements and rules and
regulations utilized by Landlord for the Building and further agrees not to unduly disturb or interfere with the business or other activities of Landlord or of other tenants or occupants of the Project. 

  
 ADDENDUM 2 

3 

 10. Costs. Tenant shall be solely responsible for and shall pay all costs, expenses and taxes
incurred in connection with the ownership, installation, operation, maintenance, use and removal of the Rooftop Equipment and the appurtenant equipment located in or on the Building, plus an administrative fee of five percent (5%). 

11. Insurance. Tenant shall cause the insurance policies maintained by Tenant pursuant to the Lease to include the Rooftop Equipment and all
related equipment and materials as part of Tenant’s insured property. 
 12. Indemnity. Tenant specifically agrees that the
indemnification of Landlord by Tenant in accordance with the Lease is deemed to include any claims arising from the installation, operation, use, maintenance or removal of the Rooftop Equipment, and the provisions of Article 10 of the Lease
are incorporated herein by reference. 
 13. Relocation. Landlord shall have the right, at its option and from time to time, upon not less
than thirty (30) days prior notice to Tenant, to relocate the Rooftop Equipment to another location in the Building adequate to afford equivalent service to Tenant. Landlord shall pay the costs of relocation reasonably incurred by Tenant in
connection with such substituted location, subject to adequate substantiation of such costs. 
 14. Removal and Restoration. Upon the
expiration or earlier termination of the Lease, the Antenna and the Connecting Equipment shall be removed from the Building by Tenant, at Tenant’s sole cost and expense, and Tenant shall pay to repair any damage caused by such removal. If
Tenant fails to remove the Antenna (if requested by Landlord to be removed) and any related Connecting Equipment (to the extent applicable) and repair the Building upon the expiration or earlier termination of the Lease, Landlord, upon thirty
(30) days’ written notice to Tenant, may do so at Tenant’s expense. The provisions of this Section 14 shall survive the expiration or earlier termination of the Lease. If any tenant of the Building under a lease in effect
on the date hereof has a right to an antenna, and Landlord is unable to accommodate such antenna (for any reason, including without limitation, physical or technical limitations regarding the use and operability thereof and any restrictions imposed
by any governmental authority), but would be able to do so if the Antenna is removed, then Landlord shall have the right, at its option, upon not less than fifteen (15) days prior notice to Tenant, to require the removal of the Antenna by
Tenant. Upon such removal, the rights contained in this Rooftop Space Addendum shall terminate, except for any accrued and unperformed obligations and liabilities hereunder. 

15. Termination. Landlord shall have the right to terminate this Rooftop Space Addendum and the rights of Tenant hereunder (i) upon three
(3) months prior written notice in the event Landlord determines that due to a change of use or any redevelopment of the Project or the Building, the Rooftop Equipment can no longer be operated (provided that any election to terminate in such
event shall be made on a non discriminatory basis); or (ii) Tenant’s use unreasonably interferes with an essential building system or function, which interference cannot be remedied; or (iii) the operation of the Rooftop Equipment
interferes with the equipment or operations of any of the existing tenants, licensees, or occupants of the Project. This Rooftop Space Addendum shall also terminate upon any destruction or condemnation affecting the use or operation of the Rooftop
Equipment hereunder, unless otherwise agreed in writing by Landlord and Tenant. If this Rooftop Space Addendum is terminated as set forth herein, no amounts will be refunded or otherwise paid to Tenant and Tenant shall remain responsible for
removing Tenant’s Rooftop Equipment and restoring the Building in accordance with the terms of this Rooftop Space Addendum. 

  
 ADDENDUM 2 

4 

 16. Default. If any of the conditions set forth in this Rooftop Space Addendum are not complied
with by Tenant, then such failure shall constitute a default by Tenant under the Lease, subject to the terms of Article 19 thereof. 
 17.
Incorporation. Except to the extent modified or superseded by the terms and provisions of this Rooftop Space Addendum, the terms and provisions of the Lease are incorporated by reference herein and shall have the same force and effect
as if set forth fully herein. 

  
 ADDENDUM 2 

5 

 SCHEDULE 1 TO ADDENDUM 2 

PLAN 
 [to be attached] 

  
 ADDENDUM 2 

6

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00227-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00227-of-00352.parquet"}]]