Document:

exv10w62

 

Exhibit 10.62

CONSTRUCTION LOAN AGREEMENT

for a loan in the amount of

$74,000,000

MADE BY AND BETWEEN

REPUBLIC 20TH STREET LLC,

a Delaware limited liability company,

As Borrower

AND

KEYBANK NATIONAL ASSOCIATION,

a national banking association,

127 Public Square,

Cleveland, Ohio 44114

as a Lender and as Administrative Agent

AND

KEYBANC CAPITAL MARKETS

as sole lead arranger and book manager

Dated as of February 16, 2007

 

 

TABLE OF CONTENTS

	 	 	 	 	 	 	 
	 	 	 	 	Page	 
	ARTICLE 1

	 	     INCORPORATION OF RECITALS AND EXHIBITS
	 	 	1	 
	1.1

	 	Incorporation of Recitals
	 	 	1	 
	1.2

	 	Incorporation of Exhibits
	 	 	1	 
	ARTICLE 2

	 	     DEFINITIONS
	 	 	1	 
	2.1

	 	Defined Terms
	 	 	1	 
	2.2

	 	Other Definitional Provisions
	 	 	18	 
	ARTICLE 3

	 	     BORROWER’S REPRESENTATIONS AND WARRANTIES
	 	 	18	 
	3.1

	 	Representations and Warranties
	 	 	18	 
	3.2

	 	Survival of Representations and Warranties
	 	 	23	 
	ARTICLE 4

	 	     LOAN AND LOAN DOCUMENTS
	 	 	24	 
	4.1

	 	Agreement to Borrow and Lend; Lenders’ Obligation to Disburse
	 	 	24	 
	4.2

	 	Loan Documents
	 	 	25	 
	4.3

	 	Term of the Loan
	 	 	26	 
	4.4

	 	Prepayments
	 	 	27	 
	4.5

	 	Required Principal Payments
	 	 	27	 
	4.6

	 	Late Charge
	 	 	27	 
	4.7

	 	Funds for Payment
	 	 	27	 
	4.8

	 	Notes
	 	 	27	 
	4.9

	 	No Setoff
	 	 	28	 
	ARTICLE 5

	 	     INTEREST
	 	 	28	 
	5.1

	 	Interest Rate
	 	 	28	 
	5.2

	 	[Intentionally Omitted.]
	 	 	30	 
	ARTICLE 6

	 	     COSTS OF MAINTAINING LOAN
	 	 	30	 
	6.1

	 	Increased Costs and Capital Adequacy
	 	 	30	 
	6.2

	 	Borrower Withholding
	 	 	32	 
	ARTICLE 7

	 	     LOAN EXPENSE AND ADVANCES
	 	 	32	 
	7.1

	 	Loan and Administration Expenses
	 	 	32	 
	7.2

	 	Fees
	 	 	32	 
	7.3

	 	[Intentionally Omitted.]
	 	 	33	 
	7.4

	 	Agent’s Attorneys’ Fees and Disbursements
	 	 	33	 
	7.5

	 	Time of Payment of Fees and Expenses
	 	 	33	 
	7.6

	 	Expenses and Advances Secured by Loan Documents
	 	 	33	 
	7.7

	 	Right of Lenders to Make Advances to Cure Borrower’s Defaults
	 	 	33	 
	ARTICLE 8

	 	     NON CONSTRUCTION REQUIREMENTS PRECEDENT TO THE OPENING OF THE LOAN
	 	 	33	 

-i-

 

TABLE OF CONTENTS
(continued)

	 	 	 	 	 	 	 
	 	 	 	 	Page	 
	8.1

	 	Non-Construction Conditions Precedent
	 	 	33	 
	ARTICLE 9

	 	     CONSTRUCTION REQUIREMENTS PRECEDENT TO THE OPENING OF THE LOAN
	 	 	36	 
	9.1

	 	Required Construction and Other Documents
	 	 	36	 
	ARTICLE 10

	 	     BUDGET AND CONTINGENCY FUND
	 	 	38	 
	10.1

	 	Budget
	 	 	38	 
	10.2

	 	Budget Line Items
	 	 	38	 
	10.3

	 	Contingency Fund
	 	 	39	 
	10.4

	 	Optional Method for Payment of Interest
	 	 	39	 
	ARTICLE 11

	 	     SUFFICIENCY OF LOAN
	 	 	39	 
	11.1

	 	Loan In Balance
	 	 	39	 
	ARTICLE 12

	 	     CONSTRUCTION PAYOUT REQUIREMENTS
	 	 	40	 
	12.1

	 	Applicability of Sections
	 	 	40	 
	12.2

	 	Monthly Payouts
	 	 	40	 
	12.3

	 	Documents to be Furnished for Each Disbursement
	 	 	40	 
	12.4

	 	Retainages
	 	 	42	 
	12.5

	 	Disbursements for Materials Stored On Site
	 	 	42	 
	12.6

	 	Disbursements for Offsite Materials
	 	 	42	 
	12.7

	 	Disbursements For Tenant Work and Allowances and Leasing Commissions
	 	 	42	 
	12.8

	 	[Intentionally omitted.]
	 	 	43	 
	ARTICLE 13

	 	     FINAL DISBURSEMENT FOR CONSTRUCTION
	 	 	44	 
	13.1

	 	Final Disbursement for Construction
	 	 	44	 
	ARTICLE 14

	 	     [reserved]
	 	 	45	 
	ARTICLE 15

	 	     OTHER COVENANTS
	 	 	45	 
	15.1

	 	Additional Covenants
	 	 	45	 
	15.2

	 	Authorized Representative
	 	 	52	 
	ARTICLE 16

	 	     CASUALTIES AND CONDEMNATION
	 	 	53	 
	16.1

	 	Agent’s Election to Apply Proceeds on Indebtedness
	 	 	53	 
	16.2

	 	Borrower’s Obligation to Rebuild and Use of Proceeds Therefor
	 	 	53	 
	ARTICLE 17

	 	     ASSIGNMENTS BY LENDERS AND BORROWER
	 	 	54	 
	17.1

	 	Prohibition of Assignments and Transfers by Borrower
	 	 	54	 
	17.2

	 	Prohibition of Transfers in Violation of ERISA
	 	 	54	 
	17.3

	 	Successors and Assigns
	 	 	55	 
	ARTICLE 18

	 	     TIME OF THE ESSENCE
	 	 	55	 
	18.1

	 	Time is of the Essence
	 	 	55	 

-ii-

 

TABLE OF CONTENTS
(continued)

	 	 	 	 	 	 	 
	 	 	 	 	Page	 
	ARTICLE 19

	 	     EVENTS OF DEFAULT
	 	 	55	 
	ARTICLE 20

	 	     LENDERS’ REMEDIES IN EVENT OF DEFAULT
	 	 	57	 
	20.1

	 	Remedies Conferred Upon Lenders
	 	 	57	 
	ARTICLE 21

	 	     GENERAL PROVISIONS
	 	 	58	 
	21.1

	 	Captions
	 	 	58	 
	21.2

	 	Modification; Waiver
	 	 	58	 
	21.3

	 	Governing Law
	 	 	59	 
	21.4

	 	Acquiescence Not to Constitute Waiver of Lenders’ Requirements
	 	 	59	 
	21.5

	 	Disclaimer by Lenders
	 	 	59	 
	21.6

	 	Partial Invalidity; Severability
	 	 	60	 
	21.7

	 	Definitions Include Amendments
	 	 	60	 
	21.8

	 	Execution in Counterparts
	 	 	60	 
	21.9

	 	Entire Agreement
	 	 	60	 
	21.10

	 	Waiver of Damages
	 	 	60	 
	21.11

	 	Claims Against Agent or Lenders
	 	 	61	 
	21.12

	 	Jurisdiction
	 	 	61	 
	21.13

	 	Set-Offs
	 	 	61	 
	21.14

	 	Distribution of Collateral Proceeds
	 	 	62	 
	ARTICLE 22

	 	     NOTICES
	 	 	62	 
	ARTICLE 23

	 	     WAIVER OF JURY TRIAL
	 	 	64	 
	ARTICLE 24

	 	     ASSIGNMENTS AND PARTICIPATIONS
	 	 	64	 
	24.1

	 	Assignments and Participations
	 	 	64	 
	24.2

	 	Several Liability
	 	 	67	 
	ARTICLE 25

	 	     AGENT
	 	 	68	 
	25.1

	 	Appointment
	 	 	68	 
	25.2

	 	Reliance on Agent
	 	 	68	 
	25.3

	 	Powers
	 	 	68	 
	25.4

	 	Disbursements
	 	 	69	 
	25.5

	 	Distribution and Apportionment of Payments
	 	 	70	 
	25.6

	 	Consents and Approvals
	 	 	72	 
	25.7

	 	Agency Provisions Relating to Collateral
	 	 	73	 
	25.8

	 	Lender Actions Against Borrower or the Collateral
	 	 	74	 
	25.9

	 	Assignment and Participation
	 	 	75	 
	25.10

	 	Ratable Sharing
	 	 	75	 

-iii-

 

TABLE OF CONTENTS
(continued)

	 	 	 	 	 	 	 
	 	 	 	 	Page	 
	25.11

	 	General Immunity
	 	 	75	 
	25.12

	 	No Responsibility for Loan, Recitals, etc
	 	 	76	 
	25.13

	 	Action on Instructions of Lenders
	 	 	76	 
	25.14

	 	Employment of Agents and Counsel
	 	 	77	 
	25.15

	 	Reliance on Documents; Counsel
	 	 	77	 
	25.16

	 	Agent’s Reimbursement and Indemnification
	 	 	77	 
	25.17

	 	Rights as a Lender
	 	 	77	 
	25.18

	 	Lenders’ Credit Decisions
	 	 	78	 
	25.19

	 	Notice of Events of Default
	 	 	78	 
	25.20

	 	Successor Agent
	 	 	78	 
	25.21

	 	Disclosure
	 	 	79	 

-iv-

 

LIST OF EXHIBITS TO LOAN AGREEMENT

	 	 	 
	Exhibit A

	 	Legal Description of Land
	Exhibit B

	 	Permitted Exceptions
	Exhibit C

	 	Form of Note
	Exhibit D

	 	Intentionally Omitted
	Exhibit E

	 	LIBOR Notice Election
	Exhibit F

	 	Insurance Requirements
	Exhibit G

	 	Architect’s Certificate
	Exhibit H

	 	Initial Budget
	Exhibit I

	 	Borrower’s Certificate
	Exhibit J

	 	Soft and Hard Cost Requisition Form
	Exhibit K

	 	Borrower’s Certificate of Compliance
	Exhibit L

	 	Assignment and Assumption Agreement
	Exhibit M

	 	Patriot Act and OFAC Transferee and Assignee Identifying Information Form

 

 

CONSTRUCTION LOAN AGREEMENT

Project Commonly Known as

“1129 20th Street”

     THIS CONSTRUCTION LOAN AGREEMENT (“Agreement”) is made as of February 16, 2007, by and
among REPUBLIC 20TH STREET LLC, a Delaware limited liability company
(“Borrower”), and KEYBANK NATIONAL ASSOCIATION, a national banking association
(“KeyBank”), its successors and assigns, individually and as a lender and administrative
agent (referred to in such capacity as “Agent” in this Agreement), and each of the undersigned
lending institutions (KeyBank, as a lender, and each such lending institution, and their respective
successors and assigns, referred to individually as “Lender” or collectively as the “Lenders”).

W I T N E S S E T H:

RECITALS

     A. Borrower is the owner of a fee simple interest in the land located at 1129 20th
Street in Washington, D.C., and which is legally described in Exhibit A attached hereto
(the “Land”). Borrower proposes to expand and renovate such building.

     B. Borrower has applied to Lenders for a loan in the amount of up to Seventy-Four Million and
No/100 Dollars ($74,000,000.00) (the “Loan”) to reimburse Borrower for and to pay for the
acquisition and development of the Project, and Lenders are willing to make the Loan on the terms
and conditions hereinafter set forth.

     NOW, THEREFORE, in consideration of the mutual covenants and agreements herein contained, the
parties hereto agree as follows:

ARTICLE 1

INCORPORATION OF RECITALS AND EXHIBITS

1.1 Incorporation of Recitals.

     The foregoing preambles and all other recitals set forth herein are made a part hereof by this reference.

1.2 Incorporation of Exhibits.

     Exhibits A through M, to this Agreement, attached hereto are incorporated in this Agreement
and expressly made a part hereof by this reference.

ARTICLE 2

DEFINITIONS

2.1 Defined Terms.

     The following terms as used herein shall have the following meanings:

     Adjusted LIBOR Rate: For any LIBOR Rate Interest Period, an interest rate per annum
equal to the sum of (A) the rate obtained by dividing (x) the LIBOR Rate for such LIBOR Rate
Interest Period by (y) a percentage equal to one hundred percent (100%) minus the Reserve
Percentage for such LIBOR Rate Interest Period and (B) the LIBOR Rate Margin.

     Adjusted Base Rate: A rate per annum equal to the sum of (a) the Prime Rate Margin
and (b) the greater of (i) the Prime Rate or (ii) one percent (1%) in excess of the Federal Funds
Effective Rate. Any change in the Adjusted Base Rate shall be effective immediately from and after
a change in the Adjusted Base Rate (or the Federal Funds Effective Rate, as applicable).

 

 

     Affiliate: An Affiliate, as applied to any Person, shall mean any other Person
directly or indirectly Controlling, Controlled by, or under common Control with, that Person.

     Agent’s Head Office: The Agent’s head office located at 127 Public Square, Cleveland,
Ohio 44114-1306, or at such other location as the Agent may designate from time to time by notice
to the Borrower and the Lenders.

     Agent’s Special Counsel: McKenna Long & Aldridge LLP or such other counsel as
selected by Agent.

     Agreement: This Construction Loan Agreement.

     Applicable Margin. On any date, the Applicable Margin set forth below based on the
percentage of the Net Rentable Area of the Project (based upon the Net Rentable Area to be in the
Project after completion of Construction) that is subject to Qualified Leases:

	 	 	 	 	 	 	 	 	 	 	 
	 	 	Percentage of Net Rentable Area	 	LIBOR Rate	 	Prime Rate
	Pricing Level	 	Subject to Qualified Leases	 	Margin	 	Margin
	Pricing Level 1

	 	Greater than or equal to 90%
	 	 	1.25	%	 	 	0.00	%
	 
	 	 	 	 	 	 	 	 	 	 
	Pricing Level 2

	 	Greater than or equal to 40%
but less than 90%
	 	 	1.45	%	 	 	0.25	%
	 
	 	 	 	 	 	 	 	 	 	 
	Pricing Level 3

	 	Less than 40%
	 	 	1.65	%	 	 	0.50	%

The initial Applicable Margin shall be at Pricing Level 3. The Applicable Margin shall not be
adjusted based upon such percentage, if at all, until the first (1st) day of the first
(1st) month following the delivery by Borrower to the Agent of the Rent Roll at the end
of a calendar month. In the event that Borrower shall fail to deliver to the Agent a monthly Rent
Roll on or before the date required by Section 15.1(o), then without limiting any other
rights of the Agent and the Lenders under this Agreement, the Applicable Margin shall be at Pricing
Level 3 until such failure is cured within any applicable cure period, in which event the
Applicable Margin shall adjust, if necessary, on the first (1st) day of the first
(1st) month following receipt of such Rent Roll.

     Applicable Rate: As such term is defined in Section 5.1(a).

     Appraisal: An MAI appraisal of the value of the Project performed by an independent
appraiser selected by the Agent who is not an employee of the Borrower, the Guarantors or any of
their Affiliates, the Agent or a Lender, the form and substance of such appraisal and the identity
of the appraiser to be in compliance with FIRREA, the rules and regulations adopted pursuant
thereto and all other regulatory laws and policies (both regulatory and internal) applicable to the
Lenders and otherwise acceptable to the Agent.

     Appraised Value: The stabilized market value of the Project as reflected in the
then-most recent Appraisal of the Project, obtained pursuant to this Agreement; subject, however,
to such reasonable adjustments to the value determined thereby as may be required by the appraisal
department of the Agent in its good faith business judgment based on criteria and factors then
generally used and considered by the Agent in determining the value of similar properties, which
review shall be conducted prior to acceptance of such Appraisal by the Agent.

     Architect: FOX Architects, LLC.

     Architect’s Certificate: A certificate in the form of Exhibit G attached
hereto executed by the Architect in favor of Lenders.

     Assignment and Assumption: An Assignment and Assumption Agreement in the form of
Exhibit L attached hereto and made a part hereof.

2

 

     Assignment of Rents: An assignment of leases and rents made by Borrower in favor of
Agent assigning all leases, subleases and other agreements relating to the use and occupancy of all
or any portion of the Project, and all present and future leases, rents, issues and profits
therefrom.

     Authorized Representative: Gary R. Siegel, Michael Green or Mark Keller.

     Bankruptcy Code: Title 11 of the United States Code entitled “Bankruptcy” as now or
hereafter in effect, or any successor thereto or any other present or future bankruptcy or
insolvency statute.

     Board. As such term is defined in Change of Control.

     Bond: A Performance Bond and Labor and Material Payment Bond in a form approved by
Agent, with each Major Subcontractor as principal, with a surety company acceptable to Agent and
licensed to do business in the State, as surety, with a dual obligee rider in favor of Agent.

     Breakage Costs: The cost to any Lender of re employing funds bearing interest at an
Adjusted LIBOR Rate (calculated based on a change in the LIBOR Rate), incurred (or reasonably
expected to be incurred) in connection with (i) any payment of any portion of the Loan bearing
interest at an Adjusted LIBOR Rate prior to the termination of any applicable LIBOR Rate Interest
Period, (ii) the conversion of an Adjusted LIBOR Rate to any other applicable interest rate on a
date other than the last day of the relevant LIBOR Rate Interest Period, or (iii) the failure of
Borrower to draw down, on the first day of the applicable LIBOR Rate Interest Period, any amount as
to which Borrower has elected a LIBOR Rate Option.

     Budget: The budget for the Project specifying all costs and expenses of every kind
and nature whatever to be incurred by Borrower in connection with the Project prior to the Maturity
Date.

     Budget Line Item: As such term is defined in Section 10.2.

     Business Day: A day of the year on which banks are not required or authorized to
close in Cleveland, Ohio.

     Capitalized Lease: A lease under which the discounted future rental payment
obligations of the lessee or the obligor are required to be capitalized on the balance sheet of
such Person in accordance with generally accepted accounting principles.

     Change of Control: A Change of Control shall exist upon the occurrence of any of the
following:

          (a) any Person (including a Person’s Affiliates and associates) or group (as that term is
understood under Section 13(d) of the Securities Exchange Act of 1934, as amended (the “Exchange
Act”) and the rules and regulations thereunder) shall have acquired beneficial ownership (within
the meaning of Rule 13d-3 under the Exchange Act) of a percentage (based on voting power, in the
event different classes of stock shall have different voting powers) of the voting stock of Parent
Guarantor equal to at least twenty percent (20%) (or with respect to Richard Kramer and Steven
Grigg and their Affiliates, an aggregate of at least forty percent (40%));

          (b) as of any date a majority of the Board of Directors or Trustees (the “Board”) of Parent
Guarantor consists of individuals who were not either (i) directors or trustees of Parent Guarantor
as of the corresponding date of the previous year, or (ii) selected or nominated to become
directors or trustees by the Corporate Governance and Nominating Committee of Parent Guarantor,
which is comprised solely of independent directors, as required by the New York Stock Exchange, and
approved by a majority of the Board of Parent Guarantor, which majority consisted of individuals
described in clause (b)(i) above, or (iii) selected or nominated to become directors or trustees by
the Corporate Governance and Nominating Committee of Parent Guarantor and approved by a majority of
the Board of Parent Guarantor, which majority consisted of individuals described in clause (b)(i)
above and individuals described in clause (b)(ii), above (excluding, in the case of both clause
(ii) and (iii) above, any individual whose initial nomination for, or assumption of office as, a
member of the Board occurs as a result of an actual or threatened solicitation of proxies or
consents for the election or removal of one or more

3

 

directors or trustees by any Person or group other than a solicitation for the election of one
or more directors or trustees by or on behalf of the Board); or

          (c) the OP Guarantor or Parent Guarantor consolidates with, is acquired by, or merges into or
with any Person (other than a merger permitted by Section 22 of the Guaranty); or

          (d) Parent Guarantor fails to own, directly, at least fifty-one percent (51%) of the economic,
voting and beneficial interests in OP Guarantor; or

          (e) Parent Guarantor shall fail to be the sole general partner of OP Guarantor, shall fail to
own such general partnership interest in OP Guarantor free of any lien, encumbrance or other
adverse claim, or shall fail to control the management and policies of OP Guarantor; or

          (f) Mark R. Keller shall cease to be the Chief Executive Officer of Parent Guarantor and a
competent and experienced successor Chief Executive Officer shall not be reasonably approved by the
Required Lenders within six (6) months of such event; or

          (g) OP Guarantor ceases to control the management of the Borrower and to be the legal and
beneficial owner of at least 51% of the membership interests in Borrower; or

          (h) OP Guarantor or any other owner of Equity Interests in Borrower shall create, incur,
assume or suffer to exist any Lien on the Equity Interests in Borrower owned by it.

     Change Order: Any request for changes in the Plans and Specifications (other than
minor field changes involving no extra cost).

     Code: The Internal Revenue Code of 1986, as amended.

     Collateral: All of (a) the property, rights and interests of the Borrower that are or
are intended to be subject to the security interests, assignments, and mortgage liens created by
the Security Documents, including, without limitation, the Project, and (b) the Guaranty.

     Commitment: The maximum amount each Lender has agreed to lend to Borrower as part of
the Loan (which amounts are set forth below the signature line of each Lender), subject to
modification by each Assignment and Assumption.

     Completion Conditions: Delivery to Agent of the following items in form satisfactory
to the Agent:

               (A) Required Permits. Evidence that the Borrower has obtained all Required Permits
from such Governmental Authority as may be required under applicable laws and requirements for the
permanent use and occupancy of the Improvements for their intended uses, together with copies of
all such Required Permits (it being acknowledged that with respect to any portion of the Project to
be occupied by a Tenant which has not been leased, Borrower shall deliver a shell certificate of
occupancy);

               (B) Approval by Lender’s Consultant. Notification from the Lender’s Consultant to the
effect that the Improvements have been completed in a good and workmanlike manner in accordance
with the Plans and Specifications;

               (C) Certificate of the Borrower’s Architect. Certificate of the Borrower’s architect
that the Improvements have been completed in accordance with the Plans and Specifications and that
the Improvements comply with all applicable laws and requirements and Governmental Approvals and
are in all respects ready for use and occupancy;

               (D) Payment of Costs. Evidence satisfactory to Agent that all sums due in connection
with the construction of the Improvements have been paid or discharged in full (whether by bonding
or

4

 

otherwise) and that no party claims or has a right to claim any statutory or common law lien
arising out of the construction of the Improvements for the supplying of labor, material, equipment
and/or services in connection therewith;

               (E) Final Lien Waivers. Final lien waivers in such form as may be permitted by
applicable law to remove or dissolve any unfiled lien claims, or such other form satisfactory to
the Agent from the General Contractor, and such laborers, suppliers, subcontractors and materialmen
as may be requested by the Agent, duly executed and notarized (or with respect to any lien claims
for which final lien waivers are not provided, evidence satisfactory to Agent that such lien claims
have been discharged in full (whether by bonding or otherwise));

               (F) Acceptance by Tenants. Evidence satisfactory to Agent that any Tenants of the
Project for which Tenant Work has been completed have accepted their leased premises in accordance
with their Lease;

               (G) Debt Service Coverage. The Debt Service Coverage for the most recently completed
calendar quarter shall be not less than 1.25 to 1, and Agent shall have received a duly executed
Certificate of Compliance in the form of Exhibit K attached hereto; and

               (H) Title Endorsement. An endorsement to the Title Policy fully removing any
exception for mechanics and materialman’s liens, whether filed or unfiled.

     Completion Date: The first to occur of (i) the date that is eighteen (18) months from
the Construction Commencement Date and (ii) November 16, 2008, subject to extension pursuant to
Section 15.1(b).

     Construction or construction: The construction and equipping of the Improvements in
accordance with the Plans and Specifications, and all Tenant Work and related improvements required
to be performed by Borrower under Leases and the installation of all personal property, fixtures
and equipment required for the operation of the Project.

     Construction Commencement Date: The first to occur of (i) May 16, 2007 and (ii) the
date that is 30 days from the Loan Opening Date.

     Construction Schedule: A schedule satisfactory to Agent and Lender’s Consultant,
establishing a timetable for completion of the Construction, showing, on a monthly basis, the
anticipated progress of the Construction and also showing that the Improvements can be completed on
or before the Completion Date.

     Contingency Fund: A Budget Line Item which shall represent an amount necessary to
provide reasonable assurances to Lenders that additional funds are available to be used if
additional costs and expenses are incurred or additional interest accrues on the Loan, or
unanticipated events or problems occur.

     Control: For purposes of this definition, “Control” (including, with correlative
meanings, the terms “controlling”, “controlled by” and “under common control with”), as applied to
any Person, means (a) the possession, directly or indirectly, of the power to vote twenty percent
(20%) or more of the stock, shares, voting trust certificates, beneficial interests, partnership
interests, member interests or other interests having voting power for the election of directors of
such Person or otherwise to direct or cause the direction of the management and policies of that
Person, whether through the ownership of voting securities or by contract or otherwise, or (b) the
ownership of (i) a general partnership interest, (ii) a managing member’s or manager’s interest in
a limited liability company or (iii) a limited partnership interest or preferred stock (or other
ownership interest) representing twenty percent (20%) or more of the outstanding limited
partnership interests, preferred stock or other ownership interests of such Person.

     Debt Service Coverage: With respect to a particular period, the ratio of (a) the Net
Operating Income of the Project for the most recently completed calendar quarter, annualized to (b)
the Total Annual Debt Service.

5

 

     Deed of Trust: A deed of trust, assignment of leases and rents, security agreement
and fixture filing, executed by Borrower for the benefit of Agent and the Lenders securing this
Agreement, the Notes, and all obligations of Borrower in connection with the Loan, granting a first
priority lien on Borrower’s fee simple interest in the Project, subject only to the Permitted
Exceptions.

     Default or default: Any event, circumstance or condition, which, if it were to
continue uncured, would, with notice or lapse of time or both, constitute an Event of Default
hereunder.

     Default Rate: A rate per annum equal to three percentage points (300 basis points) in
excess of the Adjusted Base Rate, but not at any time in excess of the highest rate permitted by
law.

     Defaulting Lender: As such term is defined in Section 25.5(b).

     Deficiency Deposit: As such term is defined in Section 11.1.

     Derivatives Contract: Any and all rate swap transactions, basis swaps, credit
derivative transactions, forward rate transactions, commodity swaps, commodity options, forward
commodity contracts, equity or equity index swaps or options, bond or bond price or bond index
swaps or options or forward bond or forward bond price or forward bond index transactions, interest
rate options, forward foreign exchange transactions, cap transactions, floor transactions, collar
transactions, currency swap transactions, cross-currency rate swap transactions, currency options,
spot contracts, or any other similar transactions or any combination of any of the foregoing
(including any options to enter into any of the foregoing), whether or not any such transaction is
governed by or subject to any master agreement. Not in limitation of the foregoing, the term
“Derivatives Contract” includes any and all transactions of any kind, and the related
confirmations, which are subject to the terms and conditions of, or governed by, any form of master
agreement published by the International Swaps and Derivatives Association, Inc., any International
Foreign Exchange Master Agreement, or any other master agreement, including any such obligations or
liabilities under any such master agreement.

     Derivatives Termination Value: In respect of any one or more Derivatives Contracts,
after taking into account the effect of any legally enforceable netting agreement relating to such
Derivatives Contracts, (a) for any date on or after the date such Derivatives Contracts have been
closed out and termination value(s) determined in accordance therewith, such termination value(s),
and (b) for any date prior to the date referenced in clause (a) the amount(s) determined as the
mark-to-market value(s) for such Derivatives Contracts, as determined based upon one or more
mid-market or other readily available quotations provided by any recognized dealer in such
Derivatives Contracts (which may include the Agent or any Lender).

     Eligible Assignee: (i) Any Lender; (ii) any commercial bank, savings bank, savings
and loan association or similar financial institution which (A) has total assets of Five Billion
Dollars ($5,000,000,000) or more, (B) is “well capitalized” within the meaning of such term under
the regulations promulgated under the auspices of the Federal Deposit Insurance Corporation
Improvement Act of 1991, (C) in the reasonable judgment of the Agent, is engaged in the business of
lending money and extending credit, and buying loans or participations in loans under credit
facilities substantially similar to those extended under this Agreement, and (D) in the reasonable
judgment of the Agent, is operationally and procedurally able to meet the obligations of a Lender
hereunder to the same degree as a commercial bank; (iii) any insurance company in the business of
writing insurance which (A) has total assets of Five Billion Dollars ($5,000,000,000) or more (B)
is “best capitalized” within the meaning of such term under the applicable regulations of the
National Association of Insurance Commissioners, and (C) meets the requirements set forth in
subclauses (C) and (D) of clause (ii) above; and (iv) any other financial institution having total
assets of Five Billion Dollars ($5,000,000,000) (including a mutual fund or other fund under
management of any investment manager having under its management total assets of Five Billion
Dollars ($5,000,000,000) or more) which meets the requirement set forth in subclauses (C) and (D)
of clause (ii) above; provided that each Eligible Assignee must (w) be organized under the Laws of
the United States of America, any state thereof or the District of Columbia, or, if a commercial
bank, be organized under the Laws of the United States of America, any state thereof or the
District of Columbia, the Cayman Islands or any country which is a member of the Organization for
Economic Cooperation and Development, or a political subdivision of such a country, (x) act under
the Loan Documents through a branch, agency or funding office located in the United States of
America, (y) be exempt from withholding of tax on interest

6

 

and deliver the documents related thereto pursuant to the Internal Revenue Code as in effect
from time to time and (z) not be the Borrower or an Affiliate of the Borrower.

     Engineering Report: An engineering report prepared by licensed engineer satisfactory
to Agent to the satisfaction of Agent that the existing improvements at the Project will support
the new improvements contemplated by the Plans and Specifications.

     Environmental Indemnity: An environmental indemnity from the Borrower and Guarantors,
jointly and severally, indemnifying Agent and the Lenders with regard to all matters related to
Hazardous Material and other environmental matters.

     Environmental Proceedings: Any environmental proceedings, whether civil (including
actions by private parties), criminal, or administrative proceedings, relating to the Project.

     Environmental Report: An environmental report prepared at Borrower’s expense by a
qualified environmental consultant approved by Agent, dated not more than three (3) months prior to
the date of this Agreement and addressed to Agent (or subject to separate letter agreement
permitting Agent to rely on such environmental report).

     Equity Interests: With respect to any Person, shares of capital stock of (or other
ownership or profit interests in) such Person, warrants, options or other rights for the purchase
or other acquisition from such Person of shares of capital stock of (or other ownership or profit
interests in) such Person, securities convertible into or exchangeable for shares of capital stock
of (or other ownership or profit interests in) such Person or warrants, rights or options for the
purchase or other acquisition from such Person of such shares (or such other interests), and other
ownership or profit interests in such Person (including, without limitation, partnership, member or
trust interests therein), whether voting or nonvoting, and whether or not such shares, warrants,
options, rights or other interests are authorized or otherwise existing as of any date of
determination.

     ERISA: The Employee Retirement Income Security Act of 1974, as amended, and the
regulations promulgated thereunder from time to time.

     Event of Default: As such term is defined in Article 19.

     Extended Maturity Date: As such term is defined in Section 4.3.

     Extension Option: As such term is defined in Section 4.3.

     Extension Term: The period of time commencing on the day after the Initial Maturity
Date and ending on the Extended Maturity Date.

     Federal Funds Effective Rate: Shall mean, for any day, the rate per annum (rounded
upward to the nearest on one-hundredth of one percent (1/100 of 1%)) announced by the Federal
Reserve Bank of Cleveland on such day as being the weighted average of the rates on overnight
federal funds transactions arranged by federal funds brokers on the previous trading day, as
computed and announced by such Federal Reserve Bank in substantially the same manner as such
Federal Reserve Bank computes and announces the weighted average it refers to as the “Federal Funds
Effective Rate.”

     FIRREA: The Financial Institutions Reform, Recovery And Enforcement Act of 1989, as
amended from time to time.

     General Contract: The general contract between Borrower and General Contractor,
pertaining to the construction of all onsite and offsite improvements for the Project.

     General Contractor: Jones Lang LaSalle Construction, Limited Partnership.

7

 

     Governmental Approvals: Collectively, all consents, licenses, and permits and all
other authorizations or approvals required from any Governmental Authority for the Construction in
accordance with the Plans and Specifications.

     Governmental Authority: Any federal, state, county or municipal government, or
political subdivision thereof, any governmental or quasi governmental agency, authority, board,
bureau, commission, department, instrumentality, or public body, or any court, administrative
tribunal, or public utility.

     Guarantor(s): Parent Guarantor and the OP Guarantor, individually or collectively, as
the context shall imply.

     Guaranty: That certain Guaranty dated of even date herewith, executed by each
Guarantor in favor of Agent and Lenders, as the same may be modified, amended or ratified.

     Hazardous Material: Means and includes gasoline, petroleum, asbestos containing
materials, explosives, radioactive materials or any hazardous or toxic material, substance or waste
which is defined by those or similar terms or is regulated as such under any Law of any
Governmental Authority having jurisdiction over the Project or any portion thereof or its use,
including: (i) any “hazardous substance” defined as such in (or for purposes of) the Comprehensive
Environmental Response, Compensation and Liability Act, 42 U.S.C.A. § 9601(14) as may be amended
from time to time, or any so called “superfund” or “superlien” Law, including the judicial
interpretation thereof; (ii) any “pollutant or contaminant” as defined in 42 U.S.C.A. § 9601(33);
(iii) any material now defined as “hazardous waste” pursuant to 40 C.F.R. Part 260; (iv) any
petroleum, including crude oil or any fraction thereof; (v) natural gas, natural gas liquids,
liquefied natural gas, or synthetic gas usable for fuel; (vi) any “hazardous chemical” as defined
pursuant to 29 C.F.R. Part 1910; (vii) any other toxic substance or contaminant that is subject to
any other Law or other past or present requirement of any Governmental Authority; and (viii) any
Mold or Mold Condition. Any reference above to a Law, includes the same as it may be amended from
time to time, including the judicial interpretation thereof.

     Improvements: The improvements more particularly described in the Plans and
Specifications, and offsite improvements and together with any existing improvements not to be
demolished.

     In Balance or in balance: As such term is defined in Article 11.

     Including or including: Including but not limited to.

     Indebtedness: With respect to a Person, at the time of computation thereof, all of
the following (without duplication): (a) all obligations of such Person in respect of money
borrowed (other than trade debt incurred in the ordinary course of business which is not more than
sixty (60) days past due); (b) all obligations of such Person, whether or not for money borrowed
(i) represented by notes payable, or drafts accepted, in each case representing extensions of
credit, (ii) evidenced by bonds, debentures, notes or similar instruments, or (iii) constituting
purchase money indebtedness, conditional sales contracts, title retention debt instruments or other
similar instruments, upon which interest charges are customarily paid or that are issued or assumed
as full or partial payment for property or services rendered; (c) obligation of such Person as a
lessee or obligor under a Capitalized Lease; (d) all reimbursement obligations of such Person under
any letters of credit or acceptances (whether or not the same have been presented for payment); (e)
all Off-Balance Sheet Obligations of such Person; (f) all obligations of such Person in respect of
any purchase obligation, repurchase obligation, takeout commitment or forward equity commitment, in
each case evidenced by a binding agreement (excluding any such obligation to the extent the
obligation can be satisfied by the issuance of Equity Interests), (g) net obligations under any
Derivatives Contract not entered into as a hedge against existing Indebtedness, in an amount equal
to the Derivatives Termination Value thereof; (h) all Indebtedness of other Persons which such
Person has guaranteed or is otherwise recourse to such Person (including guaranties of customary
exceptions for fraud, misapplication of funds, environmental indemnities, violation of “special
purpose entity” covenants, and other similar exceptions to recourse liability), including liability
of a general partner in respect of liabilities of a partnership in which it is a general partner
which would constitute “Indebtedness” hereunder, any obligation to supply funds to or in any manner
to invest directly or indirectly in a Person, to maintain working capital or equity capital of a
Person or otherwise to maintain net worth, solvency or other financial condition of a Person, to
purchase indebtedness, or to assure the owner of indebtedness against loss,

8

 

including, without limitation, through an agreement to purchase property, securities, goods,
supplies or services for the purpose of enabling the debtor to make payment of the indebtedness
held by such owner or otherwise; and (i) all Indebtedness of another Person secured by (or for
which the holder of such Indebtedness has an existing right, contingent or otherwise, to be secured
by) any Lien on property or assets owned by such Person, even though such Person has not assumed or
become liable for the payment of such Indebtedness or other payment obligation.

     Initial Maturity Date: February 16, 2010, or such earlier date on which the Loan
shall become due and payable pursuant to the terms hereof.

     Internal Revenue Code: The Internal Revenue Code of 1986, as amended from time to
time.

     Land: As such term is defined in Recital A.

     Late Charge: As such term is defined in Section 4.6.

     Laws: Collectively, all federal, state and local laws, statutes, codes, ordinances,
orders, rules and regulations, including judicial opinions or precedential authority in the
applicable jurisdiction.

     Leases: The collective reference to all leases, subleases and occupancy agreements
affecting the Project or any part thereof now existing or hereafter executed and all amendments,
modifications or supplements thereto approved in writing by Agent.

     Lender(s): As defined in the opening paragraph of this Agreement.

     Lender’s Consultant: An independent consulting architect, inspector, and/or engineer
designated by Agent in Agent’s sole discretion.

     Lender Default Obligation: As such term is defined in Section 25.5(b).

     Lender Reply Period: As such term is defined in Section 25.6.

     Lien: Any lien, security interest or other charge or encumbrance of any kind, or any
other type of preferential arrangement, including, without limitation, the lien or retained
security title of a conditional vendor and any easement, right of way or other encumbrance on title
to real property.

     LIBOR Business Day: A Business Day on which dealings in U.S. dollars are carried on
in the London Interbank Market.

     LIBOR Rate: For any LIBOR Rate Interest Period, the average rate (rounded upwards to
the nearest 1/16th) as shown by Reuters at which deposits in U.S. dollars are offered by first
class banks in the London Interbank Market at approximately 11:00 a.m. (London time) on the day
that is two (2) LIBOR Business Days prior to the first day of such LIBOR Rate Interest Period with
a maturity approximately equal to such LIBOR Rate Interest Period and in an amount approximately
equal to the amount to which such LIBOR Rate Interest Period relates, adjusted for reserves and
taxes if required by future regulations. If Reuters no longer reports such rate or Agent
determines in good faith that the rate so reported no longer accurately reflects the rate available
to Lenders in the London Interbank Market, Agent may select a replacement index.

     LIBOR Rate Interest Period: With respect to each amount bearing interest at a LIBOR
based rate, a period of one, two, three or six months, to the extent deposits with such maturities
are available to Agent (provided that until such time as Agent gives notice to Borrower that
syndication of the Loan has been completed, no LIBOR Rate Interest Period shall exceed one month),
commencing on a LIBOR Business Day, as selected by Borrower provided, however, that (i) any LIBOR
Rate Interest Period which would otherwise end on a day which is not a LIBOR Business Day shall
continue to and end on the next succeeding LIBOR Business Day, unless the result would be that such
LIBOR Rate Interest Period would be extended to the next succeeding calendar month, in which case
such LIBOR Rate Interest Period shall end on the next preceding LIBOR Business Day, (ii) any LIBOR
Rate Interest

9

 

Period which begins on a day for which there is no numerically corresponding date in the
calendar month in which such LIBOR Rate Interest Period would otherwise end shall instead end on
the last LIBOR Business Day of such calendar month, and (iii) Borrower may not select a LIBOR Rate
Interest Period which would end after the Maturity Date.

     LIBOR Rate Margin: The rate per annum indicated in the definition of Applicable
Margin as the LIBOR Rate Margin.

     LIBOR Rate Option: As defined in Section 5.1(b).

     Loan: As defined in Recital B.

     Loan Amount: The maximum amount of the Loan as set forth in Section 4.1(a) as
reduced by principal payments made from time to time.

     Loan Documents: The collective reference to this Agreement, the documents and
instruments listed in Section 4.2, and all the other documents and instruments entered into
from time to time, evidencing or securing the Loan or any obligation of payment thereof or
performance of Borrower’s or Guarantors’ obligations in connection with the transaction
contemplated hereunder, each as amended.

     Loan Opening Date: The date of the first disbursement of proceeds of the Loan, other
than proceeds advanced as of the date of this Agreement for the acquisition of the Project and
closing costs.

     Major Subcontractor: Any subcontractor under a Major Subcontract.

     Major Subcontracts: All subcontracts between the General Contractor and any
subcontractors and material suppliers which provide for an aggregate contract price equal to or
greater than $100,000.00.

     Material Adverse Change or material adverse change: A Material Adverse Change or
material adverse change as to Borrower or the Project shall occur if there is a material adverse
effect on (a) the business activities, properties, assets, financial condition or results of
operations of Borrower, individually or in the aggregate with other events in excess of
$1,000,000.00 of value; (b) the ability of Borrower to perform any of its obligations under the
Loan Documents; or (c) the validity or enforceability of any of the Loan Documents or the rights or
remedies of Agent or the Lenders thereunder. A Material Adverse Change or material adverse change
as to Guarantors shall occur if there is a material adverse effect on (a) the business activities,
properties, assets, financial condition or results of operations of any Guarantor and its
Subsidiaries considered as a whole, individually or in the aggregate with other events in excess of
$10,000,000.00 of value; (b) the ability of any Guarantor to perform any of its obligations under
the Loan Documents; or (c) the validity or enforceability of any of the Loan Documents or the
rights or remedies of Agent or the Lenders thereunder.

     Maturity Date: The Initial Maturity Date, provided, if Borrower timely satisfies the
conditions to extend the term of the Loan pursuant to Section 4.3(b), then the Maturity
Date shall be extended to the Extended Maturity Date, or such earlier date on which the Loan shall
become due and payable pursuant to the terms hereof.

     Mold: Surficial or airborne microbial constituents, regardless of genus, species, or
whether commonly referred to as mildew, mold, mold spores, fungi, bacteria or similar description.

     Mold Condition: The growth or existence of Mold, in such condition, location or
quantity as would, individually or in the aggregate, in the judgment of a qualified environmental
engineer, have any material adverse effect on (i) human health or the environment; (ii) the value
or condition of the Project; or (iii) the business or financial condition as a whole of the
Borrower or the Project.

     Moody’s: Moody’s Investors Service, Inc. and its successors.

10

 

     Net Operating Income: For any calendar quarter, the sum of (a) gross income from
operations of the Project derived from arm’s length leases with unaffiliated third parties, service
fees or charges, (excluding capital gains income derived from the sale of assets and other items of
income which the Agent reasonably determines are unlikely to occur in any subsequent period),
less (b) operating expenses, including cleaning, utilities, administrative, landscaping,
repairs, management fees (equal to the greater of 2% per annum of the aggregate gross revenues from
the Project and the actual management fees paid), a capital improvement reserve equal to $0.10 per
square foot of Net Rentable Area of the Project (based upon the Net Rentable Area to be in the
Project following completion of Construction), and fixed expenses (such as insurance, real estate
and other taxes), assuming for each of the foregoing categories of expenses, for any period during
which ninety-five percent (95%) of the Net Rentable Area of the Project is not leased and occupied,
a ninety-five percent (95%) occupancy level. All operating expenses shall be related to the
Project, shall be for services from arm’s length third party transactions or equivalent to the
same, and shall exclude all expenses for capital improvements and replacements, debt service and
depreciation or amortization of capital expenditures and other similar non-cash items. Income and
expenses shall be calculated on an annualized and “normalized” basis (rents shall be straight lined
and expenses not payable on a monthly basis (such as taxes and insurance) shall be allocated across
an annual period). In the event that actual occupancy shall exceed ninety-five percent (95%), the
gross revenues shall be reduced to that level which would be received if occupancy did not exceed
ninety-five percent (95%). The vacancy factor to be applied to reduce the calculation of income
from the Project shall not be applicable to space leased to Tenants under Qualified Leases (i)
which Leases have a term of not less than 10 years and (ii) which Tenants have a Rating of
BBB-/Baaa3 or better (for clarification the Net Rentable Area leased to such Tenants shall be
subtracted from the total Net Rentable Area of the Project, and the income vacancy factor shall be
applied to the balance of the Project).

     Net Rentable Area. With respect to the Project, the floor area of the improvements
available for leasing to tenants, the manner of such determination to be reasonably acceptable to
Agent.

     Notes: Promissory notes, aggregating the Loan Amount, executed by Borrower and
payable to the order of each Lender, in the amount of its respective Commitment, evidencing the
Loan.

     Notice: As defined in Article 22.

     Obligations. All indebtedness, obligations and liabilities of the Borrower to any of
the Lenders or the Agent existing on the date of this Agreement or arising thereafter, direct or
indirect, joint or several, absolute or contingent, matured or unmatured, liquidated or
unliquidated, secured or unsecured, arising by contract, operation of law or otherwise, in each
case arising or incurred under this Agreement or any of the other Loan Documents or in respect of
any disbursements of the Loan or the Notes or other instruments at any time evidencing any thereof.

     OFAC: Office of Foreign Asset Control of the Department of the Treasury of the United
States of America

     OFAC Review Process: That certain review process established by Agent to determine if
any potential transferee of any interests or any assignee of any portion of the Loan or any of
their members, officers or partners are a party with whom Agent and any Lender are restricted from
doing business under (i) the regulations of OFAC, including those Persons named on OFAC’s Specially
Designated and Blocked Persons list, or (ii) any other statute, executive order or other
governmental action or list (including the September 24, 2001 Executive Order Blocking Property and
Prohibiting Transactions With Persons Who Commit, Threaten to Commit, or Support Terrorism.

     Off-Balance Sheet Obligations: Liabilities and obligations of the Borrower in respect
of “off-balance sheet arrangements” (as defined in the SEC Off-Balance Sheet Rules) which Parent
Guarantor would be required to disclose in the “Management’s Discussion and Analysis of Financial
Condition and Results of Operations” section of Parent Guarantor’s report on Form 10-Q or Form 10-K
(or their equivalents) which Parent Guarantor is required to file with the Securities and Exchange
Commission (or any Governmental Authority substituted therefore). As used in this definition, the
term “SEC Off-Balance Sheet Rules” means the Disclosure in Management’s Discussion and Analysis
About Off-Balance Sheet Arrangements, Securities Act Release No. 33-8182, 68 Fed. Reg. 5982 (Feb.
5, 2003) (codified at 17 CFR pts. 228, 229 and 249).

11

 

     OP Credit Agreement: The Senior Secured Revolving Credit Agreement dated as of May 1,
2006, by and among OP Guarantor, Parent Guarantor, KeyBank, individually and as Agent, and the
other banks from time to time a party thereto, as the same may be modified, amended or restated.

     OP Guarantor: Republic Property Limited Partnership, a Delaware limited partnership.

     Opening of the Loan or Loan Opening: The first disbursement of Loan proceeds, other
than proceeds advanced as of the date of this Agreement for the acquisition of the Project and
closing costs.

     Parent Guarantor. Republic Property Trust, a Maryland real estate investment trust.

     Patriot Act Customer Identification Process: That certain customer identification and
review process established by the Agent pursuant to the requirements of 31 U.S.C. §5318(1) and 31
C.F.R. §103.121 to verify the identity of all permitted transferees of interests in the Borrower
and any assignees of a portion of the Loan hereunder.

     Percentage: With respect to each Lender, the percentage that its Commitment
constitutes of the maximum amount of the Loan.

     Permitted Exceptions: Those matters listed on Exhibit B to which title to the
Project may be subject at the date of this Agreement and thereafter such other title exceptions as
Agent may reasonably approve in writing.

     Person: Any individual, corporation, limited liability company, partnership, trust,
unincorporated association, business, or other legal entity, and any government or any governmental
agency or political subdivision thereof.

     Plans and Specifications: Detailed plans and specifications for the Improvements, as
approved by Agent pursuant to Section 9.1(f), as modified hereafter with Agent’s prior
written approval or as otherwise expressly permitted by this Agreement.

     Pricing Level. Such term shall have the meaning set forth in the definition of
Applicable Margin.

     Prime Rate: That interest rate established from time to time by KeyBank National
Association as its prime rate, whether or not such rate is publicly announced; the Prime Rate may
not be the lowest interest rate charged by KeyBank National Association for commercial or other
extensions of credit.

     Prime Rate Margin. The rate per annum indicated in the definition of Applicable
Margin as the Prime Rate Margin.

     Pro-Forma Debt Service Coverage. The ratio of (a) stabilized net operating income
(based on the calculation of the stabilized first year income less expenses of the Project
projected in the Appraisal for the Project approved by Agent) to (b) the Total Annual Debt Service.

     Pro-Forma Projection: A pro forma statement of projected income and expenses of the
Project.

     Project: The collective reference to (i) the fee simple interest in the Land,
together with all buildings, structures and improvements located or to be located thereon,
including the Improvements, (ii) all rights, privileges, easements and hereditaments relating or
appertaining thereto, and (iii) all personal property, fixtures and equipment required or
beneficial for the operation thereof.

     Qualified Leases. A Qualified Lease shall be a Lease with respect to the occupancy of
the Project which satisfies each of the following requirements: (i) such Lease is an arm’s-length
transaction with a Person not related to or an Affiliate of Borrower or any owner of Borrower or
any Person owning a direct or a 5% or greater indirect interest in Borrower; (ii) the annual rent
payable under such Lease is not less than ninety five percent (95%) of the pro forma rental rates
in the Appraisal for the Project approved by Agent; (iii) such Lease shall have a minimum

12

 

term of no less than seven (7) years; (iv) the tenant improvement allowance shall be a
commercially reasonable amount; (v) such Lease shall be on the form approved by Agent or otherwise
approved by Agent or the Required Lenders as required by this Agreement; (vi) such Lease shall be
in full force and effect and no default by Borrower, a Tenant or any guarantor shall exist under
such Lease which has not been cured within any applicable notice and cure period; and (vii) such
Tenant and any guarantor of such Lease shall not be subject to any bankruptcy, reorganization,
arrangement, insolvency, readjustment of debt, dissolution or liquidation proceeding.

     Rating: The senior unsecured non-credit-enhanced debt rating of a Tenant as
determined by S&P and/or Moody’s from time to time.

     Record: The grid attached to any Note, or the continuation of such grid, or any other
similar record, including computer records, maintained by Agent with respect to any Loan referred
to in such Note.

     REIT Status: With respect to Parent Guarantor, its status as a real estate investment
trust as defined in §856(a) of the Code.

     Rent Roll. A report prepared by the Borrower showing for the Project its occupancy,
lease expiration dates, lease rent, security deposits, and other information as Agent may
reasonably require.

     Required Lenders: Lenders holding Percentages aggregating at least sixty-six and
two-thirds percent (66.66%).

     Required Permits: Collectively, all applicable building permits, certificates of
occupancy, environmental permits, utility permits, land use permits, wetland permits and any other
permits, approvals or licenses issued by any Governmental Authority which are required in
connection the Construction or operation of the Project.

     Reserve Percentage: For any LIBOR Rate Interest Period, that percentage which is
specified three (3) Business Days before the first day of such LIBOR Rate Interest Period by the
Board of Governors of the Federal Reserve System (or any successor) or any other governmental or
quasi-governmental authority with jurisdiction over Lenders for determining the maximum reserve
requirement (including, but not limited to, any marginal reserve requirement) for Lenders with
respect to liabilities constituting of or including (among other liabilities) Eurocurrency
liabilities in an amount equal to that portion of the Loan affected by such LIBOR Rate Interest
Period and with a maturity equal to such LIBOR Rate Interest Period.

     Security Documents. The Deed of Trust, the Assignment of Rents, the Environmental
Indemnity, the Guaranty, and any other agreement, document or instrument now or hereafter securing
the Obligations.

     S&P: Standard & Poor’s Rating Services, a division of The McGraw-Hill Companies, Inc.
and its successors.

     State: The District of Columbia.

     Subcontracts: Subcontracts for labor or materials to be furnished to the Project.

     Subsidiary. As defined in the OP Credit Agreement.

     Taking: Any condemnation for public use of, or damage by reason of, the action of any
Governmental Authority, or any transfer by private sale in lieu thereof, either temporarily or
permanently.

     Tax Protest: As defined in Section 3.1(cc).

     Tenant: The tenant under a Lease.

     Tenant Estoppel Certificate. A tenant estoppel certificate which shall be fully
completed by the Tenant and which shall be in form and substance satisfactory to Agent.

13

 

     Tenant Work. Work that Borrower is obligated to perform pursuant to Leases for
individual Tenants in their respective leased premises in the Improvements.

     Title Insurer: Commonwealth Land Title Insurance Company, or such other title
insurance company licensed in the State as may be approved in writing by Agent.

     Title Policy: An ALTA Mortgagee’s Loan Title Insurance Policy with extended coverage
issued by the Title Insurer insuring the lien of the Deed of Trust as a valid first, prior and
paramount lien upon the Project and all appurtenant easements, and subject to no other exceptions
other than the Permitted Exceptions.

     Total Annual Debt Service: The aggregate of debt service payments for a 12 month
period on the stated principal amount of the Loan, assuming (i) a per annum interest rate (herein,
“Assumed Rate”) equal to the greater of (x) six percent (6.00%), and (y) one and one-quarter
percent (1.25%) above the yield on ten year United States Treasury notes as of the close of
business on the day preceding the date of calculation, as announced on Bloomberg.com or another
reliable source selected by the Agent, and (ii) monthly payments of principal and interest based on
an amortization period of thirty (30) years.

     Transfer: Any sale, transfer, lease (other than a Lease approved by Agent or which is
permitted by the terms of this Agreement), conveyance, alienation, pledge, assignment, mortgage,
encumbrance hypothecation or other disposition of (a) all or any portion of the Project or any
portion of any other security for the Loan, (b) all or any portion of the Borrower’s right, title
and interest (legal or equitable) in and to the Project or any portion of any other security for
the Loan, or (c) any interest in Borrower or any interest in any entity which directly or
indirectly holds an interest in, or directly or indirectly controls, Borrower.

     Unavoidable Delay: Any delay in the construction of the Project, caused by natural
disaster, fire, earthquake, floods, explosion, extraordinary adverse weather conditions, inability
to procure or a general shortage of labor, equipment, facilities, energy, materials or supplies in
the open market, failure of transportation, strikes or lockouts (but not as a result of disputes
with or actions by a Tenant) for which Borrower has notified Agent in writing.

     Voting Interests: Shares of capital stock issued by a corporation, or equivalent
Equity Interests in any other Person, the holders of which are ordinarily, in the absence of
contingencies, entitled to vote for the election of directors (or persons performing similar
functions) of such Person, even if the right so to vote has been suspended by the happening of such
a contingency.

2.2 Other Definitional Provisions.

     All terms defined in this Agreement shall have the same meanings when used in the Notes, Deed
of Trust, any other Loan Documents, or any certificate or other document made or delivered pursuant
hereto. The words “hereof”, “herein” and “hereunder” and words of similar import when used in this
Agreement shall refer to this Agreement.

ARTICLE 3

BORROWER’S REPRESENTATIONS AND WARRANTIES

3.1 Representations and Warranties.

     To induce Agent and Lenders to execute this Agreement and perform its obligations hereunder,
Borrower hereby represents and warrants to Agent and Lenders as follows:

     (a) Borrower has good and marketable fee simple title to the Project, subject only to the
Permitted Exceptions.

     (b) Except as previously disclosed to Agent in writing, no litigation or proceedings are
pending, or to the best of Borrower’s knowledge threatened, against Borrower or any Guarantor,
which could, if adversely

14

 

determined, cause a Material Adverse Change with respect to Borrower, any Guarantor or the
Project. There are no Environmental Proceedings and Borrower has no knowledge of any threatened
Environmental Proceedings or any facts or circumstances which may give rise to any future
Environmental Proceedings.

     (c) Borrower is a duly organized and validly existing Delaware limited liability company and
has full power and authority to execute, deliver and perform all Loan Documents to which Borrower
is a party, and such execution, delivery and performance have been duly authorized by all requisite
action on the part of Borrower.

     (d) No consent, approval or authorization of or declaration, registration or filing with any
Governmental Authority or nongovernmental person or entity, including any creditor, partner, or
member of Borrower or any Guarantor, is required in connection with the execution, delivery and
performance of this Agreement or any of the Loan Documents other than the recordation of the Deed
of Trust, Assignment of Leases and Rents and the filing of UCC 1 Financing Statements and as to the
performance of Borrower’s Construction obligations hereunder, the issuance of the building permit
for the Construction, except for such consents, approvals or authorizations of or declarations or
filings with any Governmental Authority or non governmental person or entity where the failure to
so obtain would not have an adverse effect on Borrower or such Guarantor or which have been
obtained as of any date on which this representation is made or remade.

     (e) The execution, delivery and performance of this Agreement, the execution and payment of
the Notes and the granting of the Deed of Trust and other security interests under the other Loan
Documents have not constituted and will not constitute, upon the giving of notice or lapse of time
or both, a breach or default under any other agreement to which Borrower or Guarantor is a party or
may be bound or affected, or a violation of any law or court order which may affect the Project,
any part thereof, any interest therein, or the use thereof; provided that Borrower may not commence
Construction until the issuance of a building permit.

     (f) There is no default under this Agreement, or any of the other Loan Documents, nor any
condition which, after notice or the passage of time or both, would constitute a default or an
Event of Default under said documents.

     (g) (i) No Taking of any portion of the Project, (ii) no Taking or relocation of any roadways
abutting the Project, (iii) no proceeding to deny access to the Project from any point or planned
point of access to the Project, has commenced or, to the best of Borrower’s knowledge, is
contemplated by any Governmental Authority, and (iv) neither the Project nor any part thereof is
now materially damaged or injured as result of any fire, explosion, accident, flood or other
casualty (it being acknowledged that in connection with the Construction there shall be demolition
work to the existing shell).

     (h) The amounts set forth in the Budget present a full and complete itemization by category of
all costs, expenses and fees which Borrower reasonably expects to pay or reasonably anticipates
becoming obligated to pay to complete the Construction and operate the Project (until the Project
achieves breakeven operations). Borrower is unaware of any other such costs, expenses or fees
which are material and are not covered by the Budget.

     (i) Neither the construction of the Improvements nor the use of the Project when completed and
the contemplated accessory uses will violate (i) any Laws (including subdivision, zoning, building,
environmental protection and wetland protection Laws), or (ii) any building permits, restrictions
of record, or agreements affecting the Project or any part thereof. Neither the zoning
authorizations, approvals or variances nor any other right to construct or to use the Project is to
any extent dependent upon or related to any real estate other than the Land. All Governmental
Approvals required for the Construction in accordance with the Plans and Specifications have been
obtained or will be obtained prior to the Loan Opening, except for those approved by Agent, and all
Laws relating to the Construction and operation of the Improvements have been complied with and all
permits and licenses required for the operation of the Project which cannot be obtained until the
Construction is completed can be obtained if the Improvements are completed in accordance with the
Plans and Specifications.

     (j) The Project will have adequate water, gas and electrical supply, storm and sanitary
sewerage facilities, other required public utilities, fire and police protection, and means of
access between the Project and public highways; none of the foregoing will be foreseeably delayed
or impeded by virtue of any requirements under

15

 

any applicable Laws. No such utility services are subject to any moratorium, or, to the best
of Borrower’s knowledge, would be subject to any threatened moratorium, imposed by any authority
having jurisdiction.

     (k) No brokerage fees or commissions are payable by or to any person in connection with this
Agreement or the Loan to be disbursed hereunder.

     (l) (i) The Borrower has furnished to Agent: (a) the consolidated balance sheet of Parent
Guarantor and its Subsidiaries as of September 30, 2006 and the related consolidated statement of
income and cash flow for the calendar year then ended certified by the chief financial or
accounting officer of Parent Guarantor, (b) as of the date of this Agreement, an unaudited
statement of Net Operating Income for the Project for the period ending December 31, 2007
reasonably satisfactory in form to the Agent and certified by the chief financial or accounting
officer of Parent Guarantor as fairly presenting the Net Operating Income for such property for
such period, and (c) certain other financial information relating to the Borrower, the Guarantors
and the Project. Such balance sheet and statements have been prepared in accordance with generally
accepted accounting principles and fairly present the consolidated financial condition of Parent
Guarantor and its Subsidiaries as of such dates and the consolidated results of the operations of
Parent Guarantor and its Subsidiaries for such periods. There are no liabilities, contingent or
otherwise, of the OP Guarantor, Parent Guarantor or any of their respective Subsidiaries or
Borrower involving material amounts not disclosed in said financial statements and the related
notes thereto.

          (ii) Since September 30, 2006 or the date of the most recent financial statements delivered
pursuant to the Loan Documents, as applicable, there has occurred no materially adverse change in
the financial condition, prospects or business of any Guarantor and their respective Subsidiaries
taken as a whole or of Borrower as shown on or reflected in the consolidated balance sheet of the
Parent Guarantor as of September 30, 2006 or the balance sheet of Borrower as of the date of this
Agreement, or its consolidated (as applicable) statement of income or cash flows for the calendar
year then ended, other than changes in the ordinary course of business that have not and could not
reasonably be expected to have a Material Adverse Change.

     (m) Except as disclosed by Borrower to Agent in writing, (i) the Project is in a clean, safe
and healthful condition, and, except for materials used in the ordinary course of construction,
maintenance and operation of the Project, is free of all Hazardous Material other than de minimis
quantities used in the ordinary course of business of the Project and is in compliance with all
applicable Laws; (ii) neither Borrower nor, to the best knowledge of Borrower, any other person or
entity, has ever caused or permitted any Hazardous Material to be placed, held, located or disposed
of on, under, at or in a manner to affect the Project, or any part thereof, and the Project has
never been used (whether by Borrower or, to the best knowledge of Borrower, by any other person or
entity) for any activities involving, directly or indirectly, the use, generation, treatment,
storage, transportation, or disposal of any Hazardous Material; (iii) neither the Project nor
Borrower is subject to any existing, pending, or, to the best of Borrower’s knowledge, threatened
investigation or inquiry by any Governmental Authority, and the Project is not subject to any
remedial obligations under any applicable Laws pertaining to health or the environment; and (iv)
there are no underground tanks, vessels, or similar facilities for the storage, containment or
accumulation of Hazardous Material of any sort on, under or affecting the Project.

     (n) The Project is taxed separately without regard to any other property and for all purposes
the Project may be mortgaged, conveyed and otherwise dealt with as an independent parcel.

     (o) Except for Leases which have been provided to and approved by Agent in writing or which
are not required to be approved by Agent or the Required Lenders hereunder, Borrower and its agents
have not entered into any Leases, subleases or other arrangements for occupancy of space within the
Project. True, correct and complete copies of all Leases, as amended, have been delivered to
Agent. All Leases are in full force and effect. Neither Borrower nor any Tenant is in default
under any Lease and Borrower has disclosed to Agent in writing any material default by the Tenant
under any Lease.

     (p) When the Construction is completed in accordance with the Plans and Specifications, no
building or other improvement will encroach upon any property line, building line, setback line,
side yard line or any recorded or visible easement (or other easement of which Borrower is aware or
has reason to believe may exist) with respect to the Project.

16

 

     (q) The Loan is not being made for the purpose of purchasing or carrying “margin stock” within
the meaning of Regulation T, U or X issued by the Board of Governors of the Federal Reserve System,
and Borrower agrees to execute all instruments necessary to comply with all the requirements of
Regulation U of the Federal Reserve System.

     (r) Borrower is not a party in interest to any plan defined or regulated under ERISA, and the
assets of Borrower are not “plan assets” of any employee benefit plan covered by ERISA or Section
4975 of the Internal Revenue Code.

     (s) Borrower is not a “foreign person” within the meaning of Section 1445 or 7701 of the
Internal Revenue Code.

     (t) Borrower uses no trade name other than its actual name set forth herein. The principal
place of business of Borrower is as stated in Article 22 (although the Borrower may also
maintain an office at the Project).

     (u) Borrower’s place of formation or organization is the State of Delaware. As of the date of
this Agreement, the OP Guarantor is the sole member of the Borrower.

     (v) All statements set forth in the Recitals are true and correct.

     (w) Neither Borrower nor any Guarantor is (or will be) a person with whom Lenders are
restricted from doing business under OFAC (including, those Persons named on OFAC’s Specially
Designated and Blocked Persons list) or under any statute, executive order (including, the
September 24, 2001 Executive Order Blocking Property and Prohibiting Transactions With Persons Who
Commit, Threaten to Commit, or Support Terrorism), or other governmental action and is not and
shall not engage in any dealings or transactions or otherwise be associated with such persons. In
addition, Borrower hereby agrees to provide the Lenders with any additional information that the
Lenders deem necessary from time to time in order to ensure compliance with all applicable Laws
concerning money laundering and similar activities.

     (x) The execution and delivery of this Agreement and the other Loan Documents to which the
Borrower or the Guarantors are to become a party will result in valid and legally binding
obligations of such Person enforceable against it in accordance with the respective terms and
provisions hereof and thereof, except as enforceability is limited by bankruptcy, insolvency,
reorganization, moratorium or other laws relating to or affecting generally the enforcement of
creditors’ rights and except to the extent that availability of the remedy of specific performance
or injunctive relief is subject to the discretion of the court before which any proceeding therefor
may be brought.

     (y) The Project is not owned or operated under or by reference to any registered or protected
trademark, tradename, servicemark or logo.

     (z) None of the Borrower or Guarantors is an “investment company”, or an “affiliated company”
or a “principal underwriter” of an “investment company”, as such terms are defined in the
Investment Company Act of 1940.

     (aa) The Plans and Specifications and construction of the Project pursuant thereto and the use
and occupancy of the Project contemplated thereby do not violate any existing Leases.

     (bb) Each of the contracts for construction of the Project is in full force and effect and the
Borrower and the other parties thereto are in compliance with their respective obligations therein.

     (cc) There are no unpaid or outstanding real estate or other taxes or assessments on or
against the Project or any part thereof which are payable by the owner thereof. Except for the
protest or reduction proceeding filed by Borrower’s predecessor-in-interest with respect to real
estate taxes assessed against the Project for the fiscal year October 1, 2006 to September 30, 2007
(the “Tax Protest”), no abatement proceedings are pending with reference to any real estate taxes
assessed against the Project. To the best of Borrower’s knowledge, there are no

17

 

betterment assessments or other special assessments presently pending with respect to any part
of the Project, and the Borrower has received no written notice of any such special assessment
being contemplated.

     (dd) The Borrower has received no notice of, and otherwise has no knowledge of, any violation
of any applicable agreement affecting the Borrower or the Project.

     (ee) The Borrower has furnished the Agent with true and complete sets of the Plans and
Specifications to date. The Plans and Specifications so furnished to the Agent comply (and the
Improvements when constructed in substantial accordance with the Plans and Specifications will
likewise comply) with all Laws, all Government Approvals, and all restrictions, covenants,
easements and other agreements affecting the Project, and have been approved by the Tenants to the
extent required under the Leases and on or before the Opening of the Loan by each Governmental
Authority only to the extent required for construction of the Improvements.

     (ff) The Budget accurately reflects all Budget Line Items as of the date thereof or as of the
date of any amendments thereto, as applicable.

     (gg) The Borrower has not received any written notice from any insurer or its agent requiring
performance of any work with respect to the Land or the Improvements or canceling or threatening to
cancel any policy of insurance, and the Project complies with the requirements of the Borrower’s
and General Contractor’s insurance carriers, as applicable.

     (hh) As of the date of this Agreement and after giving effect to the transactions contemplated
by this Agreement and the other Loan Documents, including all Loans made or to be made hereunder,
neither the Borrower nor any Guarantor is insolvent on a balance sheet basis such that the sum of
such Person’s assets exceeds the sum of such Person’s liabilities, the Borrower and each Guarantor
is able to pay its debts as they become due, and the Borrower and each Guarantor has sufficient
capital to carry on its business.

     (ii) All of the representations and warranties made by or on behalf of the Borrower or the
Guarantors in this Agreement and the other Loan Documents or any document or instrument delivered
to the Agent or the Lenders pursuant to or in connection with any of such Loan Documents are true
and correct in all material respects, and none of the Borrower or the Guarantors has failed to
disclose such information as is necessary to make such representations and warranties not
misleading.

3.2 Survival of Representations and Warranties.

     Borrower agrees that all of the representations and warranties set forth in Section
3.1 and elsewhere in this Agreement are true as of the date hereof, and, except for matters
which have been disclosed by Borrower and approved by Required Lenders in writing, will be true at
the Loan Opening and at all times thereafter. Each request for a disbursement under the Loan
Documents shall constitute a reaffirmation of such representations and warranties, as deemed
modified in accordance with the disclosures made and approved as aforesaid, as of the date of such
request. It shall be a condition precedent to the initial advance upon the execution of this
Agreement, the Loan Opening and each subsequent disbursement that each of said representations and
warranties is true and correct as of the date of such requested disbursement as deemed modified in
accordance with the disclosures made and approved as aforesaid. Each disbursement of Loan proceeds
shall be deemed to be a reaffirmation by Borrower that each of the representations and warranties
is true and correct as of the date of such disbursement as deemed modified in accordance with the
disclosures made and approved as aforesaid. In addition, at Agent’s request, Borrower shall
reaffirm such representations and warranties as deemed modified in accordance with the disclosures
made and approved as aforesaid in writing prior to each disbursement hereunder.

ARTICLE 4

LOAN AND LOAN DOCUMENTS

4.1 Agreement to Borrow and Lend; Lenders’ Obligation to Disburse.

18

 

     Subject to the terms, provisions and conditions of this Agreement and the other Loan
Documents, Borrower agrees to borrow from Lenders and Lenders agree to lend to Borrower the Loan,
for the purposes and subject to all of the terms, provisions and conditions contained in this
Agreement. If Lender consists of more than one party, the obligations of each such party with
respect to the amount it has agreed to loan to Borrower shall be several (and not joint and
several) and shall be limited to its Percentage of the Loan and of each advance.

     (a) The principal amount of the Loan shall not exceed the lesser of (a) Seventy-Four Million
and No/100 Dollars ($74,000,000.00), (b) 70% of the Appraised Value of the Project as set out in
the Appraisal, (c) 75% of the total cost of the Project as set out in the Budget approved by Agent
hereunder, or (d) the maximum principal amount as will result in a Pro Forma Debt Service Coverage
of at least 1.20 to 1. If after the date of this Agreement, the Lenders determine that the
Appraised Value of the Project is such that the Loan Amount exceeds seventy percent (70%) of the
Appraised Value of the Project, then the Loan Amount shall be reduced to not greater than 70% of
the Appraised Value of the Project (or such lesser amount as provided in this Agreement), and
Borrower shall be required to provide evidence reasonably satisfactory to Agent that Borrower has
invested cash equity in the Project so that the Loan is deemed In Balance.

     (b) Lenders agree, upon Borrower’s compliance with and satisfaction of all conditions
precedent to the Loan Opening and provided the Loan is In Balance, no Material Adverse Change has
occurred with respect to Borrower, any Guarantor, or the Project and no default or Event of Default
has occurred and is continuing hereunder, to open the Loan to reimburse Borrower for or to pay for
a portion of the costs incurred by Borrower in connection with the acquisition and development of
the Project and the construction of the Improvements, to the extent provided for in the Budget.
Notwithstanding anything in this Agreement to the contrary, the initial advance as of the date of
this Agreement shall be limited to the purchase price of the Land, and no other disbursements other
than disbursements from the interest reserve shall be made until the conditions to the Opening of
the Loan have been satisfied.

     (c) After the Opening of the Loan, Borrower shall be entitled to receive further successive
disbursements of the proceeds of the Loan in accordance with Articles 9, 12 and
13 within ten (10) Business Days after compliance with all conditions precedent thereto,
provided that (i) the Loan remains In Balance; (ii) Borrower has complied with all conditions
precedent to disbursement from time to time including the requirements of Section 3.2 and
Articles 8, 9, 12 and 13; (iii) no Material Adverse Change has
occurred with respect to Borrower, any Guarantor, or the Project and (iv) no Event of Default and
no default exists hereunder or under any other Loan Document.

     (d) To the extent that Agent or any Lender may have acquiesced in noncompliance with any
requirements precedent to the initial advance, the Opening of the Loan or precedent to any
subsequent disbursement of Loan proceeds, such acquiescence shall not constitute a waiver by Agent
or Lenders, and Agent and Lenders may at any time after such acquiescence require Borrower to
comply with all such requirements.

     (e) Notwithstanding anything in this Agreement to the contrary, as of the date of this
Agreement the Lenders shall disburse to Borrower the amount of $61,750,000.00 for the payment of
the purchase price of the Land. On or before the date that is one (1) Business Day after the date
of this Agreement, Borrower shall pay to Agent for the account of the Lenders as a principal
prepayment of the Loan the sum of $30,457,729.50. Following such prepayment, such amount shall be
available to be reborrowed under this Agreement for the purposes set forth in this Agreement.

4.2 Loan Documents.

     Borrower agrees that it will, on or before the date of this Agreement, execute and deliver or
cause to be executed and delivered to Lenders the following documents in form and substance
acceptable to Agent:

     (a) The Loan shall be evidenced by separate promissory notes of the Borrower in substantially
the form of Exhibit C attached hereto and made a part hereof, dated of even date with this
Agreement and completed with appropriate insertions.

19

 

     (b) The Deed of Trust.

     (c) The Assignment of Rents.

     (d) The Guaranty.

     (e) The Environmental Indemnity.

     (f) A collateral assignment of construction documents, including, without limitation, the
General Contract, all architecture and engineering contracts, Plans and Specifications, permits,
licenses, approvals and development rights, together with consents to the assignment and
continuation agreements from the General Contractor, the architect and other parties reasonably
specified by Agent.

     (g) Such UCC financing statements as Agent determines are advisable or necessary to perfect or
notify third parties of the security interests intended to be created by the Loan Documents.

     (h) Such other documents, instruments or certificates as Agent and its counsel may reasonably
require, including such documents as Agent in its sole discretion deems necessary or appropriate to
effectuate the terms and conditions of this Agreement and the Loan Documents, and to comply with
the laws of the State.

4.3 Term of the Loan.

     (a) All principal, interest and other sums due under the Loan Documents shall be due and
payable in full on the Maturity Date. All references herein to the Maturity Date shall mean the
Initial Maturity Date, provided that Borrower shall have the right to extend the Maturity Date for
one (1) additional twelve (12) month term (the “Extension Option”), thereby extending the Maturity
Date to the twelve (12) month anniversary of the Initial Maturity Date (the “Extended Maturity
Date”).

     (b) Borrower may only exercise the Extension Option upon satisfying the following conditions:

          (i) Borrower shall have delivered to Agent written notice of such election no earlier than
ninety (90) days and no later than thirty (30) prior to the Initial Maturity Date;

          (ii) There must be no material adverse change in Borrower’s or any Guarantor’s financial
condition;

          (iii) Construction of the Improvements has been completed in accordance with all requirements
of this Loan Agreement including, without limitation, the Completion Conditions, and a final
certificate of occupancy has been issued (it being acknowledged that with respect to any portion of
the Project to be occupied by a Tenant which has not been leased, Borrower shall deliver a shell
certificate of occupancy);

          (iv) Such notice is accompanied by an extension fee in the amount of 15 basis points (0.15%)
of the Loan Amount;

          (v) No Event of Default and no Default shall exist;

          (vi) The Debt Service Coverage is not less than 1.25: 1.00 (and Borrower shall have delivered
to the Agent a Certificate of Compliance so certifying); and

          (vii) The representations and warranties made by the Borrower and the Guarantors in the Loan
Documents or otherwise made by on behalf of the Borrower and the Guarantors in connection therewith
or after the date thereof as deemed modified in accordance with the disclosures made and approved
as set forth in Section 3.2 above shall have been true and correct in all material respects
when made and shall also be true and correct in all material respects on the date Borrower gives
notice of its desire to exercise the Extension Option and on the Initial Maturity Date.

20

 

Any unfunded portion of the Loan which is to be used to fund Tenant Work, tenant allowances or
leasing commissions after the initial Maturity Date shall be included in the Loan Amount for the
purposes of Section 4.3(b)(iv) and (vi).

4.4 Prepayments.

     Borrower shall have the right to make prepayments of the Loan, in whole or in part, without
prepayment penalty, at any time, upon not less than three (3) days’ prior written notice to Agent.
No prepayment of all or part of the Loan shall be permitted unless same is made together with the
payment of all Breakage Costs.

4.5 Required Principal Payments.

     All principal shall be paid on the Maturity Date.

4.6 Late Charge.

     Any and all amounts due hereunder or under the other Loan Documents which remain unpaid more
than five (5) days after the date said amount was due and payable shall incur a fee (the “Late
Charge”) of four percent (4%) per annum of said amount, which payment shall be in addition to all
of Agent’s and Lenders’ other rights and remedies under the Loan Documents, provided that no Late
Charge shall apply to the final payment of principal on the Maturity Date.

4.7 Funds for Payment.

     All payments of principal, interest, facility fees, closing fees and any other amounts due
hereunder or under any of the other Loan Documents shall be made to the Agent, for the respective
accounts of the Lenders and the Agent, as the case may be, at the Agent’s Head Office, not later
than 2:00 p.m. (Cleveland time) on the day when due, in each case in lawful money of the United
States in immediately available funds. The Agent is hereby authorized to charge the accounts of
the Borrower with KeyBank, on the dates when the amount thereof shall become due and payable, with
the amounts of the principal of and interest on the Loan and all fees, charges, expenses and other
amounts owing to the Agent and/or the Lenders under the Loan Documents. Subject to the foregoing,
all payments made to Agent on behalf of the Lenders, and actually received by Agent, shall be
deemed received by the Lenders on the date actually received by Agent.

4.8 Notes.

     One Note shall be payable to the order of each Lender in the principal amount equal to such
Lender’s respective Commitment or, if less, the outstanding amount of all disbursements of the Loan
made by such Lender, plus interest accrued thereon, as set forth below. The Borrower irrevocably
authorizes Agent to make or cause to be made, at or about the time of disbursements of the Loan or
at the time of receipt of any payment of principal thereof, an appropriate notation on Agent’s
Record reflecting the making of such disbursement or (as the case may be) the receipt of such
payment. The outstanding amount of the Loan set forth on Agent’s Record shall be prima facie
evidence of the principal amount thereof owing and unpaid to such Lender, but the failure to
record, or any error in so recording, any such amount on Agent’s Record shall not limit or
otherwise affect the obligations of the Borrower hereunder or under any Note to make payments of
principal of or interest on any Note when due.

4.9 No Setoff.

     All payments by the Borrower to Agent for the account of the Lenders or Agent hereunder and
under any of the other Loan Documents shall be made without setoff or counterclaim and free and
clear of and without deduction for any taxes, levies, imposts, duties, charges, fees, deductions,
withholdings, compulsory loans, restrictions or conditions of any nature now or hereafter imposed
or levied by any jurisdiction or any political subdivision thereof or taxing or other authority
therein unless the Borrower is compelled by law to make such deduction or withholding.

21

 

ARTICLE 5

INTEREST

5.1 Interest Rate.

     (a) The Loan will bear interest at the Applicable Rate, unless the Default Rate is applicable.
The Adjusted Base Rate shall be the “Applicable Rate”, except that the Adjusted LIBOR Rate shall
be the “Applicable Rate” with respect to portions of the Loan as to which a LIBOR Rate Option is
then in effect. For each disbursement of proceeds of the Loan, Borrower shall deliver to Agent
irrevocable notice (which may be (A) verbal notice provided that Borrower delivers to Agent
facsimile confirmation within twenty four (24) hours of such verbal notice or (B) electronic mail
notice within twenty four (24) hours of such verbal notice) of the requested amount of such
disbursement (x) if such disbursement is to bear interest at the Adjusted Base Rate, not later than
11:00 a.m. Cleveland time on the second Business Day prior to the desired date of disbursement and
(y) if such disbursement is to bear interest at an Adjusted LIBOR Rate, not later than 11:00 a.m.
Cleveland time on the third Business Day prior to the desired date of disbursement. Borrower shall
pay interest in arrears on the first day of every calendar month in the amount of all interest
accrued and unpaid.

     (b) Provided that no Event of Default exists, Borrower shall have the option (the “LIBOR Rate
Option”) to elect from time to time in the manner and subject to the conditions hereinafter set
forth an Adjusted LIBOR Rate as the Applicable Rate for all or any portion of the Loan which would
otherwise bear interest at the Adjusted Base Rate.

     (c) The only manner in which Borrower may exercise the LIBOR Rate Option is by giving Agent
irrevocable notice (which may be verbal notice provided that Borrower delivers to Agent facsimile
confirmation in the form of Exhibit E attached hereto within twenty-four (24) hours) of
such exercise not later than 11:00 a.m. Cleveland time on the second LIBOR Business Day prior to
the proposed commencement of the relevant LIBOR Rate Interest Period, which written notice shall
specify: (i) the portion of the Loan with respect to which Borrower is electing the LIBOR Rate
Option, (ii) the LIBOR Business Day upon which the applicable LIBOR Rate Interest Period is to
commence and (iii) the duration of the applicable LIBOR Rate Interest Period. The Applicable Rate
for any portion of the Loan with respect to which Borrower has elected the LIBOR Rate Option shall
revert to the Adjusted Base Rate as of the last day of the LIBOR Rate Interest Period applicable
thereto (unless Borrower again exercises the LIBOR Rate Option for such portion of the Loan).
Agent shall be under no duty to notify Borrower that the Applicable Rate on any portion of the Loan
is about to revert from an Adjusted LIBOR Rate to the Adjusted Base Rate. The LIBOR Rate Option
may be exercised by Borrower only with respect to any portion of the Loan equal to or in excess of
$1,000,000. At no time may there be more than six (6) LIBOR Rate Interest Periods in effect with
respect to the Loan. Notwithstanding the foregoing, if Borrower shall elect a LIBOR Rate Option,
only so much of the outstanding principal amount of the Loan as would not become due and payable
during the applicable LIBOR Rate Interest Period shall accrue interest at the Adjusted LIBOR Rate
and the remaining principal balance shall accrue interest at the Adjusted Base Rate.

     (d) If Agent determines (which determination shall be conclusive and binding upon Borrower,
absent manifest error) (i) that Dollar deposits in an amount approximately equal to the portion of
the Loan for which Borrower has exercised the LIBOR Rate Option for the designated LIBOR Rate
Interest Period are not generally available at such time in the London interbank market for
deposits in Dollars, (ii) that the rate at which such deposits are being offered will not
adequately and fairly reflect the cost to Lenders of maintaining a LIBOR Rate on such portion of
the Loan or of funding the same for such LIBOR Rate Interest Period due to circumstances affecting
the London interbank market generally, (iii) that reasonable means do not exist for ascertaining a
LIBOR Rate, or (iv) that an Adjusted LIBOR Rate would be in excess of the maximum interest rate
which Borrower may by law pay, then, in any such event, Agent shall so notify Borrower and all
portions of the Loan bearing interest at an Adjusted LIBOR Rate that are so affected shall, as of
the date of such notification with respect to an event described in clause (ii) or
(iv) above, or as of the expiration of the applicable LIBOR Rate Interest Period with
respect to an event described in clause (i) or (iii) above, bear interest at the
Adjusted Base Rate until such time as the situations described above are no longer in effect or can
be avoided by Borrower exercising a LIBOR Rate Option for a different LIBOR Rate Interest Period.

22

 

     (e) Interest at the Applicable Rate (or Default Rate) shall be calculated for the actual
number of days elapsed on the basis of a 360-day year (or a 365-day year in the case that the
Adjusted Base Rate shall be the Applicable Rate), including the first date of the applicable period
to, but not including, the date of repayment. Whenever a payment hereunder or under any of the
other Loan Documents becomes due on a day that is not a Business Day, the due date for such payment
shall be extended to the next succeeding Business Day, and interest shall accrue during such
extension.

     (f) Borrower shall pay all Breakage Costs incurred from time to time by Lenders upon demand
within fifteen (15) Business Days of receipt of written notice from Agent.

     (g) If the introduction of or any change in any Law, regulation or treaty, or in the
interpretation thereof by any Governmental Authority charged with the administration or
interpretation thereof, shall make it unlawful for any Lender to maintain the Applicable Rate at an
Adjusted LIBOR Rate with respect to the Loan or any portion thereof, or to fund the Loan or any
portion thereof in Dollars in the London interbank market, or to give effect to its obligations
regarding the LIBOR Rate Option as contemplated by the Loan Documents, then (1) Agent shall notify
Borrower that Lenders are no longer able to maintain the Applicable Rate at an Adjusted LIBOR Rate,
(2) the LIBOR Rate Option shall immediately terminate, (3) the Applicable Rate for any portion of
the Loan for which the Applicable Rate is then an Adjusted LIBOR Rate shall automatically be
converted to the Adjusted Base Rate, and (4) Borrower shall pay to Agent the amount of Breakage
Costs (if any) incurred by Lenders in connection with such conversion. Thereafter, Borrower shall
not be entitled to exercise the LIBOR Rate Option until such time as the situation described herein
is no longer in effect or can be avoided by Borrower exercising a LIBOR Rate Option for a LIBOR
Rate Interest Period.

     (h) Notwithstanding anything in this Agreement or the other Loan Documents to the contrary,
all agreements between or among the Borrower, the Guarantors, the Lenders and the Agent, whether
now existing or hereafter arising and whether written or oral, are hereby limited so that in no
contingency, whether by reason of acceleration of the maturity of any of the Obligations or
otherwise, shall the interest contracted for, charged or received by the Lenders exceed the maximum
amount permissible under applicable law. If, from any circumstance whatsoever, interest would
otherwise be payable to the Lenders in excess of the maximum lawful amount, the interest payable to
the Lenders shall be reduced to the maximum amount permitted under applicable law; and if from any
circumstance the Lenders shall ever receive anything of value deemed interest by applicable law in
excess of the maximum lawful amount, an amount equal to any excessive interest shall be applied to
the reduction of the principal balance of the Obligations and to the payment of interest or, if
such excessive interest exceeds the unpaid balance of principal of the Obligations, such excess
shall be refunded to the Borrower. All interest paid or agreed to be paid to the Lenders shall, to
the extent permitted by applicable law, be amortized, prorated, allocated and spread throughout the
full period until payment in full of the principal of the Obligations (including the period of any
renewal or extension thereof) so that the interest thereon for such full period shall not exceed
the maximum amount permitted by applicable law. The Borrower agrees to pay an effective rate of
interest that is the sum of the applicable rate as stated in this Agreement plus any additional
rate of interest resulting from any charges of interest or in the nature of interest paid or to be
paid in connection with any of the Loan Documents. This Section shall control all agreements
between or among the Borrower, the Guarantor, the Lenders and the Agent.

5.2 [Intentionally Omitted.]

ARTICLE 6

COSTS OF MAINTAINING LOAN

6.1 Increased Costs and Capital Adequacy.

     (a) Borrower recognizes that the cost to Lenders of maintaining the Loan or any portion
thereof may fluctuate and, Borrower agrees to pay Agent additional amounts to compensate Lenders
for any increase in its actual costs incurred in maintaining the Loan or any portion thereof
outstanding or for the reduction of any amounts received or receivable from Borrower as a result
of:

          (i) any change after the date hereof in any applicable Law, regulation or treaty, or in the
interpretation or administration thereof, or by any domestic or foreign court, (A) changing the
basis of taxation of

23

 

payments under this Agreement to any Lender (other than taxes imposed on all or any portion of
the overall net income or receipts of any Lender), or (B) imposing, modifying or applying any
reserve, special deposit or similar requirement against assets of, deposits with or for the account
of, credit extended by, or any other acquisition of funds for loans by any Lender (which includes
the Loan or any applicable portion thereof) (provided, however, that Borrower shall
not be charged again the Reserve Percentage already accounted for in the definition of the Adjusted
LIBOR Rate), or (C) imposing on any Lender, or the London interbank market generally, any other
condition affecting the Loan, provided that the result of the foregoing is to increase the cost to
any Lender of maintaining the Loan or any portion thereof or to reduce the amount of any sum
received or receivable from Borrower by any Lender under the Loan Documents; or

          (ii) the maintenance by a Lender of reserves in accordance with reserve requirements
promulgated by the Board of Governors of the Federal Reserve System of the United States with
respect to “Eurocurrency Liabilities” of a similar term to that of the applicable portion of the
Loan (without duplication for reserves already accounted for in the calculation of a LIBOR Rate
pursuant to the terms hereof).

     (b) If the application of any Law, rule, regulation or guideline adopted or arising out of the
report of the Basle Committee on Banking Regulations and Supervisory Practices entitled
“International Convergence of Capital Measurement and Capital Standards”, or the adoption after the
date hereof of any other Law, rule, regulation or guideline regarding capital adequacy, or any
change after the date hereof in any of the foregoing, or in the interpretation or administration
thereof by any domestic or foreign Governmental Authority, central bank or comparable agency
charged with the interpretation or administration thereof, or compliance by any Lender, with any
request or directive regarding capital adequacy (whether or not having the force of law) of any
such authority, central bank or comparable agency, has the effect of reducing the rate of return on
such Lender’s capital to a level below that which such Lender would have achieved but for such
application, adoption, change or compliance (taking into consideration the policies of such Lender
with respect to capital adequacy), then, from time to time Borrower shall pay to such Lender such
additional amounts as will compensate such Lender for such reduction with respect to any portion of
the Loan outstanding.

     (c) Any amount payable by Borrower under subsection (a) or subsection (b) of
this Section 6.1 shall be paid within fifteen (15) days of receipt by Borrower of a
certificate signed by an authorized officer of Agent setting forth the amount due and the basis for
the determination of such amount, which statement shall be conclusive and binding upon Borrower,
absent manifest error. Failure on the part of Agent to demand payment from Borrower for any such
amount attributable to any particular period shall not constitute a waiver of a Lender’s right to
demand payment of such amount for any subsequent or prior period. Agent shall use reasonable
efforts to deliver to Borrower prompt notice of any event described in subsection (a) or
(b) above, of the amount of the reserve and capital adequacy payments resulting therefrom
and the reasons therefor and of the basis of calculation of such amount; provided,
however, that any failure by Agent so to notify Borrower shall not affect Borrower’s
obligation to pay the reserve and capital adequacy payment resulting therefrom.

6.2 Borrower Withholding.

     If by reason of a change in any applicable Laws occurring after the date hereof, Borrower is
required by Law to make any deduction or withholding in respect of any taxes (other than taxes
imposed on or measured by the net income of a Lender or any franchise tax imposed on a Lender),
duties or other charges from any payment due under the Notes to the maximum extent permitted by
law, the sum due from Borrower in respect of such payment shall be increased to the extent
necessary to ensure that, after the making of such deduction or withholding, such Lender receives
and retains a net sum equal to the sum which it would have received had no such deduction or
withholding been required to be made.

ARTICLE 7

LOAN EXPENSE AND ADVANCES

7.1 Loan and Administration Expenses.

     Borrower unconditionally agrees to pay all expenses of the Loan, including all amounts payable
pursuant to Sections 7.2, 7.3 and 7.4 and any and all other fees owing to
Agent or Lenders pursuant to the Loan Documents or

24

 

any separate fee agreement, and also including, without limiting the generality of the
foregoing, all recording, filing and registration fees and charges, mortgage, intangible or
documentary taxes, all insurance premiums, title insurance premiums and other charges of the Title
Insurer, printing and photocopying expenses, survey fees and charges, cost of certified copies of
instruments, cost of premiums on surety company bonds and the Title Policy, charges of the Title
Insurer or other escrowee for administering disbursements, all fees and disbursements of Lender’s
Consultant, all appraisal fees, insurance consultant’s fees, environmental consultant’s fees,
travel related expenses and all costs and expenses incurred by Agent and Lenders in connection with
the determination of whether or not Borrower has performed the obligations undertaken by Borrower
hereunder or has satisfied any conditions precedent to the obligations of Lenders hereunder and, if
any default or Event of Default occurs hereunder or under any of the Loan Documents or if the Loan
or Notes or any portion thereof is not paid in full when and as due, all costs and expenses of
Agent and Lenders (including, without limitation, court costs and counsel’s fees and disbursements
and fees and costs of paralegals) incurred in attempting to enforce payment of the Loan and in
attempting to realize on any security or incurred in connection with the sale or disposition (or
preparation for sale or disposition) of any security for the Loan. Borrower agrees to pay all
brokerage, finder or similar fees or commissions payable in connection with the transactions
contemplated hereby and shall indemnify and hold Agent and Lenders harmless against all claims,
liabilities, costs and expenses (including attorneys’ fees and expenses) incurred in relation to
any claim by broker, finder or similar person.

7.2 Fees.

     The Borrower shall pay to KeyBank certain fees in connection with the Loan as provided
pursuant to a separate fee letter dated January 24, 2007 between OP Guarantor and KeyBank, which
fees shall be fully earned and non-refundable when paid. All such fees shall be solely for the
account of KeyBank as provided in such agreement.

7.3 [Intentionally Omitted.]

7.4 Agent’s Attorneys’ Fees and Disbursements.

     Borrower agrees to pay Agent’s attorneys’ fees and disbursements incurred in connection with
this Loan, including (i) the preparation of this Agreement, any intercreditor agreements and the
other Loan Documents and the preparation of the closing binders, (ii) the disbursement,
syndication, amendment, and administration of the Loan and (iii) the enforcement of the terms of
this Agreement and the other Loan Documents.

7.5 Time of Payment of Fees and Expenses.

     Borrower shall pay all expenses and fees incurred by Agent as of the date of this Agreement,
upon the execution and delivery of this Agreement. Borrower shall from time to time pay within
fifteen (15) days of request, the reasonable fees and expenses of the Agent in connection with the
satisfaction of the requirements to the Opening of the Loan. At the time of the Opening of the
Loan, Lenders may pay from the proceeds of the disbursement of the Loan all Loan expenses and all
fees payable to Agent or Lenders. Agent may require the payment of Agent’s outstanding fees and
expenses as a condition to any disbursement of the Loan. Agent is hereby authorized, without any
specific request or direction by Borrower, to make disbursements from time to time in payment of or
to reimburse Agent for all Loan expenses and fees (whether or not, at such time, there may be any
undisbursed amounts of the Loan allocated in the Budget for the same).

7.6 Expenses and Advances Secured by Loan Documents.

     Any and all advances or payments made by Lenders under this Article 7 from time to
time, and any amounts expended by Agent pursuant to Section 20.1(a), shall, as and when
advanced or incurred, constitute additional indebtedness evidenced by the Notes and secured by the
Deed of Trust and the other Loan Documents.

7.7 Right of Lenders to Make Advances to Cure Borrower’s Defaults.

     In the event that Borrower fails to perform any of Borrower’s covenants, agreements or
obligations contained in this Agreement or any of the other Loan Documents (after the expiration of
applicable notice and/or

25

 

grace periods, except in the event of an emergency or other exigent circumstances), Agent may
(but shall not be required to) perform any of such covenants, agreements and obligations, and any
amounts expended by Agent in so doing and shall constitute additional indebtedness evidenced by the
Notes and secured by the Deed of Trust and the other Loan Documents and shall bear interest at the
Default Rate.

ARTICLE 8

NON CONSTRUCTION REQUIREMENTS PRECEDENT

TO THE OPENING OF THE LOAN

8.1 Non-Construction Conditions Precedent.

     Borrower agrees that Lenders’ obligation to make the initial advance of the Loan and
thereafter to make further disbursements of proceeds thereof is conditioned upon Borrower’s
delivery, performance and satisfaction of the following conditions precedent in form and substance
satisfactory to Agent in its reasonable discretion:

     (a) Equity: Borrower shall have provided evidence reasonably satisfactory to Agent
that Borrower’s cash equity invested in the Project is not less than the difference between the
total Project cost as set forth in the Budget and the maximum Loan Amount; provided,
however, in no event shall Borrower’s cash equity in the Project be less than (x)
twenty-five percent (25%) of the total cost of the Project as set out in the Budget approved by
Agent hereunder, or (y) $32,147,570.00. Borrower’s cash equity must be either (i) deposited with
the Agent on or prior to the date of this Agreement and disbursed prior to the first disbursement
of Loan proceeds or (ii) used to pay direct Project costs approved by Agent with evidence of
payment delivered to Agent prior to the first disbursement of Loan proceeds.

     (b) [Intentionally Omitted].

     (c) Tenant Estoppels: Borrower shall have delivered to Agent Tenant Estoppel
Certificates from such Tenants as Agent shall require;

     (d) [Intentionally Omitted].

     (e) Title and Other Documents: Borrower shall have furnished to Agent the Title
Policy, together with legible copies of all title exception documents cited in the Title Policy and
all other legal documents affecting the Project or the use thereof;

     (f) Survey: Borrower shall have furnished to Agent a ALTA/ACSM “Class A” Land Title
Survey of the Project reasonably satisfactory to Agent. Said survey shall be dated no earlier than
ninety (90) days prior to the date of this Agreement. Such survey shall be sufficient to permit
issuance of the Title Policy in the form required by this Agreement. Such survey shall include the
legal description of the Land;

     (g) Insurance Policies: Borrower shall have furnished to Agent not less than ten (10)
days prior to the date of this Agreement policies or binders evidencing that insurance coverages
are in effect with respect to the Project and Borrower, in accordance with the Insurance
Requirements attached hereto as Exhibit F, for which the premiums have been fully prepaid
with endorsements satisfactory to Agent.

     (h) [Intentionally Omitted].

     (i) Utilities: Borrower shall have furnished to Agent (by way of utility letters or
otherwise) evidence establishing to the satisfaction of Agent that the Project when constructed
will have adequate water supply, storm and sanitary sewerage facilities, telephone, gas,
electricity, fire and police protection, means of ingress and egress to and from the Project and
public highways and any other required public utilities and that the Project is benefited by
insured easements as may be required for any of the foregoing;

26

 

     (j) Attorney Opinions: Borrower shall have furnished to Agent an opinion from counsel
for Borrower and Guarantors covering due authorization, execution and delivery and enforceability
of the Loan Documents and also containing such other legal opinions as Agent shall require;

     (k) Appraisal: Agent shall have received the Appraisal and the Appraised Value shall
be such that the Loan Amount does not exceed 70% of the Appraised Value. If the Appraisal has not
been approved by all the Lenders and the Appraised Value determined by all of the Lenders prior to
the date of this Agreement, then the Lenders shall have a reasonable amount of time after receipt
of the Appraisal to approve the Appraised Value.

     (l) Searches: Borrower shall have furnished to Agent current searches of all Uniform
Commercial Code financing statements filed in each place UCC Financing Statements are to be filed
hereunder, demonstrating the absence of adverse claims;

     (m) Financial Statements: Borrower shall have furnished to Agent current annual
financial statements of Borrower, the Guarantors and such other persons or entities connected with
the Loan as Agent may request, each in form and substance and certified by such individual as
acceptable to Agent. Borrower and the Guarantors shall provide such other additional financial
information Agent reasonably requires;

     (n) Pro Forma Projection: Borrower shall have furnished to Agent a Pro Forma
Projection covering the succeeding five year period;

     (o) Management Agreements: Borrower shall have delivered to Agent executed copies of
any leasing, management and development agreements entered into by Borrower in connection with the
Construction and/or the operation of the Project;

     (p) Flood Hazard: Agent has received evidence that the Project is not located in an
area designated by the Secretary of Housing and Urban Development as a special flood hazard area,
or flood hazard insurance acceptable to Agent in its sole discretion;

     (q) Zoning: If the Title Policy does not include a zoning endorsement, Borrower shall
have furnished to Agent a legal opinion or zoning letter as to compliance of the Project with
zoning and similar laws;

     (r) Organizational Documents: Borrower shall have furnished to Agent proof
satisfactory to Agent of authority, formation, organization and good standing in the State of its
incorporation or formation and, if applicable, qualification as a foreign entity in good standing
in the state of its incorporation or formation, of all corporate, partnership, trust and limited
liability company entities (including Borrower and each Guarantor) executing any Loan Documents,
whether in their own name or on behalf of another entity. Borrower and each Guarantor shall also
provide certified resolutions in form and content satisfactory to Agent, authorizing execution,
delivery and performance of the Loan Documents, and such other documentation as Agent may
reasonably require to evidence the authority of the persons executing the Loan Documents;

     (s) No Defaults: There shall be no uncured Default or Event of Default by Borrower
hereunder;

     (t) Easements: Borrower shall have furnished to Agent all easements reasonably
required for the construction, maintenance or operation of the Project, if any, and such easements
shall be insured by the Title Policy;

     (u) Pro Forma Debt Service Coverage: Agent shall have received evidence reasonably
satisfactory to Agent that the Pro Forma Debt Service Coverage for the Project is greater
than or equal to 1.20:1;

     (v) The Environmental Report. Borrower shall have delivered to Agent the
Environmental Report, which shall, at a minimum, (a) demonstrate the absence of any existing or
potential Hazardous Material contamination or violations of environmental Laws at the Project,
except as acceptable to Agent in its sole and absolute discretion, (b) include the results of all
sampling or monitoring to confirm the extent of existing or potential Hazardous Material
contamination at the Project, including the results of leak detection tests for each underground

27

 

storage tank located at the Project, if any, (c) describe response actions appropriate to
remedy any existing or potential Hazardous Material contamination, and report the estimated cost of
any such appropriate response, (d) confirm that any prior removal of Hazardous Material or
underground storage tanks from the Project was completed in accordance with applicable Laws, and
(e) confirm whether or not the Land is located in a wetlands district;

     (w) Rent Roll: Borrower shall have furnished to Agent a certified copy of the Rent
Roll;

     (x) Standard Form Tenant Lease. Borrower shall furnish Agent its standard form lease
for the Project; and

     (y) Additional Documents: Borrower shall have furnished to Agent such other
materials, documents, papers or requirements regarding the Project, the Leases, Borrower and any
Guarantor as Agent shall reasonably request.

ARTICLE 9

CONSTRUCTION REQUIREMENTS PRECEDENT

TO THE OPENING OF THE LOAN

9.1 Required Construction and Other Documents.

     Borrower shall cause to be furnished to Agent the following, in form and substance
satisfactory to Agent and Lender’s Consultant in all respects, for Agent’s approval in its
reasonable discretion prior to the Opening of the Loan:

     (a) Fully executed copies of the following, each satisfactory to Agent and Lender’s Consultant
in all respects: (i) a fixed or guaranteed maximum price General Contract; (ii) Major Subcontracts
executed prior to the Opening of the Loan; and (iii) all contracts with architects and engineers;

     (b) A schedule of values, including a trade payment breakdown, setting forth a description of
all contracts let by Borrower and/or the General Contractor for the design, engineering,
construction and equipping of the Improvements;

     (c) An initial sworn statement of the General Contractor, approved by Borrower, Architect and
Lender’s Consultant covering all work done and to be done, together with lien waivers covering all
work and materials for which payments have been made by Borrower prior to the Loan Opening;

     (d) Bonds in favor of Agent guaranteeing all of the obligations of each Major Subcontractor
under each Major Subcontract;

     (e) Copies of each of the Required Permits, except for those Required Permits, approvals or
licenses for operation of the Project which cannot be issued until completion of Construction, in
which event such Required Permits will be obtained by Borrower on a timely basis in accordance with
all recorded maps and conditions, and applicable building, land use, zoning and environmental
codes, statutes and regulations and will be delivered to Agent at the earliest possible date. In
all events the Required Permits to be delivered prior to the Opening of the Loan shall include full
building permits.

     (f) Full and complete detailed Plans and Specifications for the Improvements in duplicate,
prepared by the Architect;

     (g) The Construction Schedule;

     (h) The Engineering Report;

     (i) A report from Lender’s Consultant which contains an analysis of the Plans and
Specifications, the Budget, the Construction Schedule, the General Contract, all subcontracts then
existing and the Engineering Report.

28

 

Such report shall be solely for the benefit of Agent and each Lender and contain (i) an
analysis satisfactory to Agent demonstrating the adequacy of the Budget to complete the Project and
(ii) a confirmation that the Construction Schedule is realistic. Lender’s Consultant shall monitor
construction of the Project and shall visit the Project at least one (1) time each month, and shall
certify as to amounts of construction costs for all requested fundings;

     (j) The Architect’s Certificate in favor of Agent, executed by the Architect;

     (k) [Intentionally Omitted.]

     (l) Such consents to the assignment to Agent of the General Contract, the contract with the
Architect and any other contracts relating to the construction, and such amendments to the Security
Documents as Agent may reasonably require to reflect such assignments;

     (m) Certification from an engineer or other professional acceptable to Agent in a form
acceptable to Agent confirming that any wetlands located on the Land will not preclude the
development of the Project;

     (n) Subordination, non-disturbance and attornment agreements from such existing Tenants as
Agent shall require in form acceptable to Agent;

     (o) A report or written confirmation from an inspecting architect or engineer reasonably
acceptable to Agent satisfactory in form and content to the Agent, dated or updated not more than
three (3) months prior to the Opening of the Loan, addressing such matters as the Agent may
reasonably require, including without limitation that the condition of the existing Improvements is
good, that all existing Improvements were constructed and completed in a good and workmanlike
manner, that the existing Improvements satisfy all applicable building, zoning and handicapped
access laws applicable thereto, and whether or not the Project is a conforming use under applicable
zoning laws,

     (p) Written easements, agreements or permits from owners of adjoining property or right of way
as may be necessary to permit the construction of the Project or the usage or storage of equipment
or materials; and

     (q) Such other papers, materials and documents as Agent may require with respect to the
Construction.

ARTICLE 10

BUDGET AND CONTINGENCY FUND

10.1 Budget.

     Disbursement of the Loan shall be governed by the Budget for the Project, in form and
substance acceptable to Agent in Agent’s reasonable discretion. The Budget shall specify the
amount of cash equity invested in the Project, and all costs and expenses of every kind and nature
whatever to be incurred by Borrower in connection with the Project. The Budget shall include, in
addition to the Budget Line Items described in Section 10.2 below, the Contingency Fund
described in Section 10.3 below, and amounts satisfactory to Agent for soft costs and other
reserves acceptable to Agent. The initial Budget is attached hereto as Exhibit H and made
a part hereof. Once the Budget is approved by Lenders all changes to the Budget shall in all
respects be subject to the prior written approval of Agent.

10.2 Budget Line Items.

     The Budget shall include as line items (“Budget Line Items”), to the extent determined
to be applicable by Agent in its reasonable discretion, the cost of all labor, materials,
equipment, fixtures and furnishings needed for the completion of the Construction, and all other
costs, fees and expenses relating in any way whatsoever to the Construction of the Improvements,
leasing commissions, tenant improvements and tenant allowances, operating deficits, real estate
taxes, and all other sums due in connection with Construction and operation of the Project, the

29

 

Loan, and this Agreement. Borrower agrees that all Loan proceeds disbursed by Agent shall be
used only for the Budget Line Items for which such proceeds were disbursed.

     Borrower shall have the right to reallocate cost savings effected by final change order or
other appropriate final documentation to other Budget Line Items subject to Agent’s prior written
consent not to be unreasonably withheld.

     Subject to Borrower’s reallocation rights under this Section 10.2 and Section
10.3 below, Lenders shall not be obligated to disburse any amount for any category of costs set
forth as a Budget Line Item which is greater than the amount set forth for such category in the
applicable Budget Line Item. Borrower shall pay as they become due all amounts set forth in the
Budget with respect to costs to be paid for by Borrower.

10.3 Contingency Fund.

     The Budget shall contain a Budget Line Item designated for the Contingency Fund. Borrower may
at any time reallocate fifty percent (50%) of the Contingency Fund without the prior approval of
the Agent. Of the remaining fifty percent (50%) of the Contingency Fund, Borrower may, without the
prior approval of Agent, reallocate the balance of such funds pro rata based on the percentage of
completion of Construction (provided that any hard cost contingency may only be reallocated for
hard costs, not soft costs). Any additional request to reallocate funds from the Contingency Fund
shall be subject to Agent’s written approval in its reasonable discretion.

     Borrower agrees that the decision with respect to utilizing portions of the Contingency Fund
in order to keep the Loan “In Balance” shall be made by Agent in its reasonable discretion, and
that Agent may require Borrower to make a Deficiency Deposit even if funds remain in the
Contingency Fund.

10.4 Optional Method for Payment of Interest.

     For Borrower’s benefit, the Budget includes a Budget Line Item for interest payments on the
Loan. Borrower hereby authorizes Agent from time to time, for the mutual convenience of Lenders
and Borrower, to disburse Loan proceeds to pay all the then accrued interest on the Notes,
regardless of whether Borrower shall have specifically requested a disbursement of such amount (and
any such advance made without the submission by Borrower of a disbursement request shall bear
interest at the Adjusted Base Rate). Any such disbursement, if made, shall be added to the
outstanding principal balance of the Notes and shall, when disbursed, bear interest at the
Applicable Rate. The authorization hereby granted, however, shall not obligate Agent to make
disbursements of the Loan for interest payments (except upon Borrower’s qualifying for and
requesting disbursement of that portion of the proceeds of the Loan allocated for such purposes in
the Budget) nor prevent Borrower from paying accrued interest from its own funds.

ARTICLE 11

SUFFICIENCY OF LOAN

11.1 Loan In Balance.

     Anything contained in this Agreement contained to the contrary notwithstanding, it is
expressly understood and agreed that in Agent’s reasonable discretion the Loan shall at all times
be “In Balance”, on a Budget Line Item and an aggregate basis. A Budget Line Item shall be deemed
to be “In Balance” only if Agent in its reasonable discretion determines that the amount of such
Budget Line Item is sufficient for its intended purpose. The Loan shall be deemed to be “In
Balance” in the aggregate only when the total of the undisbursed portion of the Loan less the
Contingency Fund which Borrower may not reallocate pursuant to Section 10.3 without Agent’s
approval (subject to Borrower’s reallocation rights under Section 10.3), equals or exceeds
the aggregate of (a) the costs required to complete the construction of the Project in accordance
with the Plans and Specifications and the Budget, including, without limitation, all Tenant Work
required to be performed by Borrower or tenant allowances to be paid for by Borrower under Leases
or reasonably anticipated for unleased space; (b) the amounts to be paid as retainages to persons
who have supplied labor or materials to the Project; and (c) all other hard and soft costs not yet
paid for in connection with the Project, as such costs and amounts described in clauses
(a), (b) and (c) may be estimated and/or

30

 

approved in writing by Agent from time to time. Borrower agrees that if for any reason, in
Agent’s reasonable discretion, the amount of such undistributed Loan proceeds shall at any time be
or become insufficient for such purpose regardless of how such condition may be caused, Borrower
will, within ten (10) days after written request by Agent, deposit the deficiency with Agent
(“Deficiency Deposit”). The Deficiency Deposit shall first be exhausted before any further
disbursement of Loan proceeds shall be made. Lenders shall not be obligated to make any Loan
disbursements if and for as long as the Loan is not “In Balance”.

ARTICLE 12

CONSTRUCTION PAYOUT REQUIREMENTS

12.1 Applicability of Sections.

     The provisions contained in this Article 12 shall apply to the Opening of the Loan and
to all disbursements of proceeds during Construction.

12.2 Monthly Payouts.

     After the Opening of the Loan, further disbursements shall be made during Construction from
time to time as the Construction progresses, but no more frequently than once in each calendar
month. At Agent’s option following an Event of Default, disbursements may be made by Agent into an
escrow and subsequently disbursed to Borrower by the Title Insurer. If such option is exercised,
those Loan proceeds shall be deemed to be disbursed to Borrower from the date of deposit into that
escrow and interest shall accrue on those proceeds from that date, regardless of the date such
proceeds are released by the Title Insurer.

12.3 Documents to be Furnished for Each Disbursement.

     As a condition precedent to each disbursement of the Loan proceeds (including the initial
disbursement at the Opening of the Loan), Borrower shall furnish or cause to be furnished to Agent
the following documents covering each disbursement, in form and substance satisfactory to Agent:

     (a) A completed Borrower’s Certificate in the form of Exhibit I attached hereto and
made a part hereof and a completed Soft and Hard Cost Requisition Form in the form of Exhibit
J attached hereto and made a part hereof, each executed by the Authorized Representative;

     (b) A completed standard AIA Form G702 and Form G703 signed by the General Contractor and the
Project Architect, together with General Contractor’s sworn statements and unconditional waivers of
lien, and all subcontractors’, material suppliers’ and laborers’ conditional waivers of lien,
covering all work, to be paid with the proceeds of the prior draw requests, together with such
invoices, contracts or other supporting data as Agent may require to evidence that all costs for
which disbursement is sought have been incurred;

     (c) Paid invoices of $10,000 or greater (for soft costs only) together with an invoice
register for all costs on a line-by-line basis, or other evidence satisfactory to Agent that
fixtures and equipment, if any, have been paid for and are free of any lien or security interest
therein;

     (d) An examination of title indicating no intervening lien or objection to title and an
endorsement to the Title Policy issued to Agent covering the date of disbursement, increasing the
coverage under the Title Policy to the amount of the Loan that has been advanced, and showing the
Deed of Trust as a first, prior and paramount lien on the Project subject only to the Permitted
Exceptions and real estate taxes that have accrued but are not yet due and payable and particularly
that nothing has intervened to affect the validity or priority of the Deed of Trust;

     (e) Copies of any proposed or executed Change Orders on standard AIA G701 form, which have not
been previously furnished to Agent;

     (f) Copies of the General Contract and all Major Subcontracts which have been executed since
the last disbursement, together with any Bonds obtained or required to be obtained with respect
thereto;

31

 

     (g) All Required Permits and all other Governmental Approvals which have been obtained since
the last disbursement and are then needed in connection with the Project;

     (h) An updated spreadsheet in form and substance reasonably satisfactory to Agent summarizing
the status of completion of the Project, the comparison of the Budget and costs incurred to date by
line item, comparison of actual status of construction to the Construction Schedule, the amount of
equity and proceeds of the Loan funded for construction of the Project, and certifying that
Borrower is in compliance with the terms of the General Contract;

     (i) Such other instruments, documents and information as Agent or the Title Insurer may
reasonably request;

     (j) An updated Survey if reasonably required by the Title Insurance Company or the Agent if
the Agent shall reasonably believe that there exists any encroachment, any matter which might
materially and adversely affect title to the Project, or any material deviation from the Plans and
Specifications, which in each case would be reflected in an updated Survey, in which event
additional updated Surveys may be required by the Agent; and

     (k) At the option of Agent, an amendment to the Security Documents which specifically
identifies any furniture, fixtures or equipment purchased by Borrower for use in connection with
the Project.

     Disbursements shall be made ten (10) business days after receipt of all information required
by Lenders to approve the requested disbursements.

12.4 Retainages.

     At the time of each disbursement of Loan proceeds until completion of fifty percent (50%) of
the Construction (as reasonably estimated by Architect and approved by Lender’s Consultant), ten
percent (10%) of the total amount then due the General Contractor and the various contractors,
subcontractors and material suppliers for costs of the Construction shall be withheld from the
amount disbursed, and thereafter no additional retainage shall be withheld unless Borrower is
withholding retainage as to the General Contractor or any other contractors, subcontractors or
suppliers, and then retainage shall be held in such amount. The retained Loan amounts for the
Construction costs will be disbursed only at the time of the final disbursement of Loan proceeds
under Article 13 below; provided, however, upon the satisfactory completion of one hundred
percent (100%) of the work with respect to any trade (including any trade performed by the General
Contractor), Tenant Work or the delivery of all materials pursuant to a purchase order in
accordance with the Plans and Specifications as certified by the Architect and the Lender’s
Consultant, Agent may decide on a case by case basis (but shall not be obligated) to permit
retainages with respect to such trade or order, as the case may be, to be disbursed to Borrower
upon the Lender’s Consultant’s approval of all work and materials and Agent’s receipt of a final
waiver of lien with respect to such completed work or delivered materials.

12.5 Disbursements for Materials Stored On Site.

     Any requests for disbursements which in whole or in part relate to materials, equipment or
furnishings which Borrower owns and which are not incorporated into the Improvements as of the date
of the request for disbursement, but are to be temporarily stored at the Project, shall be made in
an aggregate amount not to exceed $250,000. Any such request must be accompanied by evidence
satisfactory to Agent that (i) such stored materials are included within the coverages of insurance
policies carried by Borrower, (ii) the ownership of such materials is vested in Borrower free of
any liens and claims of third parties, (iii) such materials are properly insured and protected
against theft or damage, (iv) the materials used in the Construction are not commodity items but
are uniquely fabricated for the Construction, (v) the Lender’s Consultant has viewed and inspected
the stored materials, and (vi) in the opinion of the Lender’s Consultant the stored materials are
physically secured and can be incorporated into the Project within forty five (45) days. Agent may
require separate Uniform Commercial Code financing statements to cover any such stored materials.

12.6 Disbursements for Offsite Materials.

32

 

     Agent may in its sole discretion, but shall not be obligated to, approve disbursements for
materials stored off site, in which event all of the requirements of Section 12.5 shall be
applicable to such disbursement as well as any other requirements which Agent may, in its sole
discretion, determine are appropriate under the circumstances.

12.7 Disbursements For Tenant Work and Allowances and Leasing Commissions.

     (a) Lenders shall not be obligated to make any disbursements for tenant allowances or Tenant
Work unless the applicable Tenant has accepted in writing the premises demised by its Lease, all
required certificates of occupancy or other permits have been issued with respect to such demised
premises and pursuant to such Tenant’s Lease, such Tenant is required to commence paying rent
within three (3) months from such date. These requirements shall apply notwithstanding any
contrary requirements of any Lease. Agent may in its reasonable discretion agree to approve
interim disbursements for Tenant Work or tenant allowances for credit tenants whose financial
condition and Lease terms are satisfactory to Agent. Disbursements for Tenant Work or allowances
shall not exceed $60 per square foot for space within floors 9 and 10 of the Project, or $50 per
square foot for space within floors 1-8 of the Project. Disbursements for leasing commissions
shall not exceed 4.5% of base rental due under the applicable Lease.

     (b) In addition to the other requirements in this Agreement, the first request for
disbursement for Tenant Work in connection with a specific leased space in the Project shall be
accompanied by the following, all of which shall be subject to the approval of Agent:

          (i) copies of all contracts, if not previously delivered to Agent, for the performance of such
Tenant Work;

          (ii) a cost breakdown for each trade performing Tenant Work in such leased space, and an
estimated commencement and completion date;

          (iii) an estimate of all direct costs of the Tenant Work to be performed in such leased space
which has not been contracted for or made subject to a work order or order to proceed;

          (iv) plans and specifications for the leased space, together with a certificate from an
architect acceptable to Agent that such plans and specifications comply with all Laws affecting the
Project and the lease covering such leased space; and

          (v) a fully executed Lease approved by Agent or the Required Lenders as required by this
Agreement covering such leased space.

     (c) Disbursements for leasing commissions shall be subject to the following conditions and
receipt of the following, all of which shall be subject to the approval of Agent:

          (i) a fully executed Lease approved by Agent or the Required Lenders as required by this
Agreement covering such leased space;

          (ii) an amount not to exceed fifty percent (50%) of the leasing commission due with respect to
a Lease shall be paid upon the full execution of the Lease, and the balance of the commissions
shall not be payable prior to receipt by Agent of an executed acceptance by the applicable Tenant
of the leased premises in form and substance reasonably satisfactory to Agent; and

          (iii) such certificates, lien waiver and affidavits that the Agent may reasonably request.

12.8 [Intentionally omitted.]

33

 

ARTICLE 13

FINAL DISBURSEMENT FOR CONSTRUCTION

13.1 Final Disbursement for Construction.

     Lenders will advance to Borrower the final disbursement for the cost of the Construction
(including any undisbursed retainages) when the following conditions have been complied with,
provided that all other conditions in this Agreement for disbursements have been complied with:

     (a) The Improvements have been fully completed and equipped in accordance with the Plans and
Specifications free and clear of mechanics’ liens and security interests and are ready for
occupancy;

     (b) Borrower shall have furnished to Agent “all risks” casualty insurance in form and amount
and with companies satisfactory to Agent in accordance with the requirements contained herein;

     (c) Borrower shall have furnished to Agent copies of all licenses and permits required by any
Governmental Authority having jurisdiction for the occupancy of the Improvements and the operation
thereof, including a certificate of occupancy from the municipality in which the Project is
located, or a letter from the appropriate Governmental Authority that no such certificate is
issued;

     (d) All Tenants for whom Tenant Work has been completed shall have executed acknowledgments of
acceptance of their respective premises in form and substance reasonably satisfactory to Agent;

     (e) Borrower shall have furnished an as-built plat of survey covering the completed
Improvements reasonably satisfactory to Agent;

     (f) All fixtures, furnishings, furniture, equipment and other property required for the
operation of the Project shall have been installed free and clear of all liens and security
interests, except in favor of Agent;

     (g) Borrower shall have furnished to Agent copies of all final waivers of lien and sworn
statements from contractors, subcontractors and material suppliers and an affidavit from the
General Contractor in accordance with the mechanic’s lien law of the State or as otherwise
established by Agent;

     (h) Borrower shall have furnished to Agent a certificate from the Architect or other evidence
satisfactory to Agent dated at or about the Completion Date stating that (i) the Improvements have
been completed in accordance with the Plans and Specifications, and (ii) the Improvements as so
completed comply with all applicable Laws; and

     (i) Agent shall have received a certificate from the Lender’s Consultant for the sole benefit
of Agent and Lenders that the Improvements have been satisfactorily completed in accordance with
the Plans and Specifications.

     If Borrower fails to comply with and satisfy any of the final disbursement conditions
contained in this Section 13.1 within sixty (60) days after the Completion Date, such
failure shall constitute an Event of Default hereunder.

     Notwithstanding the foregoing, Borrower may complete Tenant Work following the Completion Date
(provided that Borrower shall remain obligated to complete such work in accordance with the
applicable Lease), and the completion of such Work shall not be a condition to such final
disbursement. Borrower shall be required to satisfy the provisions of this Agreement before the
advance of Loans in order to obtain advances for Tenant Work, tenant allowances and leasing
commissions.

34

 

ARTICLE 14

[RESERVED]

ARTICLE 15

OTHER COVENANTS

15.1 Additional Covenants.

     Borrower further covenants and agrees as follows.

     (a) Opening of Loan on or Prior to Loan Opening Date. All conditions precedent to the
Opening of the Loan shall be complied with on or prior to April 16, 2007. If Borrower has not
satisfied all conditions precedent to, and otherwise qualified for, the Opening of the Loan on or
before said date Agent may (and at the request of the Required Lenders shall) terminate Lenders’
obligation to fund the Loan by written notice to Borrower and the Obligations shall immediately
become due and payable.

     (b) Construction of Improvements. The Improvements shall be constructed and fully
equipped in a good and workmanlike manner with materials of high quality, strictly in accordance
with the Plans and Specifications (or in accordance with any changes therein that may be approved
in writing by Agent or as to which Agent’s approval is not required), and such construction and
equipping will be commenced on or before the Construction Commencement Date and prosecuted with due
diligence and continuity in accordance with the Construction Schedule and fully completed not later
than the Completion Date. Notwithstanding the foregoing, amounts to be funded pursuant to this
Agreement to pay for Tenant Work, tenant allowances and leasing commissions pursuant to Section
12.7 may be funded (and the corresponding work completed) after the Completion Date. The
Completion Date shall be extended in writing by Agent by the number of days resulting from any
Unavoidable Delay in the construction of the Project, (but under no circumstances shall Agent or
Lenders be obligated to extend the Completion Date by more than ninety (90) days, provided that
Agent shall not be obligated to grant any such extension unless (a) Borrower gives notice of such
delay to Agent within ten (10) days of learning of the event resulting in such delay, (b) after
giving effect to the consequences of such delay, the Loan shall remain “In Balance” and (c) such
delay is permitted under each of the Leases, or Borrower obtains a written extension from each
Tenant whose Lease does not permit such delay.

     (c) Changes in Plans and Specifications. No changes will be made in the Plans and
Specifications without the prior written approval of Agent; provided, however, that
Borrower may make changes to the Plans and Specifications if (i) Borrower notifies Agent in writing
of such change within seven (7) days thereafter; (ii) Borrower obtains the approval of all parties
whose approval is required, including any Tenants under Leases, sureties, and any Governmental
Authority to the extent approval from such parties is required; (iii) the structural integrity of
the Improvements is not impaired; (iv) no material change in architectural appearance is effected;
(v) the performance of the mechanical, electrical, and life safety systems of the Improvements is
not affected; (vi) the cost of or reduction resulting from such change (x) does not exceed $500,000
and (y) when added to all other changes which have not been approved by Agent in writing, the
resulting aggregate cost or does not exceed $1,000,000. Changes in the scope of construction work
or to any construction related contract must be documented with a change order on the AIA Form G701
or equivalent form.

     (d) Inspection by Agent and Lenders. Borrower will cooperate with Agent in arranging
for inspections by representatives of Agent of the progress of the Construction from time to time
including an examination of (i) the Improvements, (ii) all materials to be used in the
Construction, (iii) all plans and shop drawings which are or may be kept at the construction site,
(iv) any contracts, bills of sale, statements, receipts or vouchers in connection with the
Improvements, (v) all work done, labor performed, materials furnished in and about the
Improvements, (vi) all books, contracts and records with respect to the Improvements, and (vii) any
other documents relating to the Improvements or the Construction. Borrower shall cooperate with
Lender’s Consultant to enable him to perform his functions hereunder. The Borrower shall permit
the Lenders, through the Agent or any representative designated by the Agent, and the Lender’s
Consultant, at the Borrower’s expense, to visit and inspect the Project and all materials to be
used in the construction thereof and will cooperate with the Agent and the Lender’s Consultant
during such inspections (including making available working drawings of the Plans and
Specifications); provided that this provision shall not be deemed to impose on the Lenders, the
Agent or the Lender’s Consultant any obligation to undertake such inspections. Borrower shall,
upon Agent’s or Lender’s Consultant’s request, correct any defect in the Construction or any
failure of the Construction to comply with the Plans and Specifications.

35

 

     (e) Mechanics’ Liens and Contest Thereof. Borrower will not suffer or permit any
mechanics’ lien claims to be filed or otherwise asserted against the Project or any funds due to
the General Contractor, and will promptly discharge the same in case of the filing of any claims
for lien or proceedings for the enforcement thereof, provided, however, that
Borrower shall have the right to contest in good faith and with reasonable diligence the validity
of any such lien or claim provided that Borrower posts a statutory lien bond which removes such
lien from title to the Project within twenty (20) days of written notice by Agent to Borrower of
the existence of the lien. Lenders will not be required to make any further disbursements of the
proceeds of the Loan until any mechanics’ lien claims have been removed and Lenders may, at their
option, restrict disbursements to reserve sufficient sums to pay 150% of the lien.

     (f) Settlement of Mechanics’ Lien Claims. If Borrower shall fail promptly either (i)
to discharge any such lien, or (ii) post a statutory lien bond in the manner provided in
Section 15.1(e) Agent may, at its election (but shall not be required to), procure the
release and discharge of any such claim and any judgment or decree thereon and, further, may in its
sole discretion effect any settlement or compromise of the same, or may furnish such security or
indemnity to the Title Insurer, and any amounts so expended by Agent, including premiums paid or
security furnished in connection with the issuance of any surety company bonds, shall be deemed to
constitute disbursement of the proceeds of the Loan hereunder. In settling, compromising or
discharging any claims for lien, Agent shall not be required to inquire into the validity or amount
of any such claim.

     (g) Renewal of Insurance. Borrower shall cause insurance policies to be maintained in
compliance with Exhibit F at all times. Borrower shall timely pay all premiums on all
insurance policies required hereunder, and as and when additional insurance is required, from time
to time, during the progress of Construction, and as and when any policies of insurance may expire,
furnish to Agent, premiums prepaid, additional and renewal insurance policies with companies,
coverage and in amounts satisfactory to Agent in accordance with Section 8.1(g).

     (h) Payment of Taxes. Borrower shall pay all real estate taxes and assessments and
charges of every kind upon the Project before the same become delinquent, provided, however, that
Borrower shall have the right to pay such tax under protest or to otherwise contest any such tax or
assessment, but only if (i) such contest has the effect of preventing the collection of such taxes
so contested and also of preventing the sale or forfeiture of the Project or any part thereof or
any interest therein, (ii) Borrower has notified Agent of Borrower’s intent to contest such taxes,
and (iii) Borrower has deposited security in form and amount satisfactory to Agent, in its sole
discretion, and has increased the amount of such security so deposited promptly after Agent’s
request therefor. If Borrower fails to commence such contest or, having commenced to contest the
same, and having deposited such security required by Agent for its full amount, shall thereafter
fail to prosecute such contest in good faith or with due diligence, or, upon adverse conclusion of
any such contest, shall fail to pay such tax, assessment or charge, Agent may, at its election (but
shall not be required to), pay and discharge any such tax, assessment or charge, and any interest
or penalty thereon, and any amounts so expended by Agent shall be deemed to constitute
disbursements of the Loan proceeds hereunder (even if the total amount of disbursements would
exceed the face amount of the Notes). Borrower shall furnish to Agent evidence that taxes are paid
at least five (5) days prior to the last date for payment of such taxes and before imposition of
any penalty or accrual of interest. Borrower shall keep Agent informed of any material
developments in connection with, and the resolution of, the Tax Protest.

     (i) Escrow Accounts. Borrower shall, following the occurrence of any Event of
Default, make insurance and tax escrow deposits, in amounts reasonably determined by Agent from
time to time as being needed to pay taxes and insurance premiums when due, in an interest bearing
escrow account held by Agent in Agent’s name and under its sole dominion and control. All payments
deposited in the escrow account, and all interest accruing thereon, are pledged as additional
collateral for the Loan. Notwithstanding Agent’s holding of the escrow account, nothing herein
shall obligate Agent or any Lender to pay any insurance premiums or real property taxes with
respect to any portion of the Project unless the Event of Default has been cured to the
satisfaction of Agent. If the Event of Default has been satisfactorily cured, Agent shall make
available to Borrower such funds as may be deposited in the escrow account from time to time for
Borrower’s payment of insurance premiums or real property taxes due with respect to the Project.

     (j) Personal Property. All of Borrower’s personal property, fixtures, attachments and
equipment delivered upon, attached to or used in connection with the Construction or the operation
of the Project shall always be located at the Project and shall be kept free and clear of all
liens, encumbrances and security interests.

36

 

     (k) Leasing Restrictions. Without the prior written consent of Agent, Borrower and
Borrower’s agents shall not (i) enter into any lease which is not a Qualified Lease without the
prior written approval of the Required Lenders, and in addition Borrower shall not enter into any
Lease (or combination of Leases with the same or a related Tenant) for more than 10,000 square feet
of Net Rentable Area without the prior written approval of the Agent, (ii) modify, amend or waive
any provision of any Lease for more than 10,000 square feet or terminate any Lease, or (iii) accept
any rental payment more than one (1) month in advance of its due date. Borrower shall provide
Agent with a copy of all Leases for more than 10,000 square feet or amendments thereto no less than
ten (10) days prior to execution of such Leases, and copies of any other Leases or amendments
promptly after execution. Borrower shall provide Agent with a copy of the fully executed original
of all Leases promptly following their execution. All such Leases shall be on a form approved by
Agent without material modification unless otherwise approved by Agent or the Required Lenders, as
applicable. At Agent’s request, Borrower shall cause all new Tenants to execute subordination,
non-disturbance and attornment agreements reasonably satisfactory to Agent. Agent reserves the
right to subordinate the Deed of Trust to any Lease.

     (l) Defaults Under Leases. Borrower will not suffer or permit any breach or default
to occur in any of Borrower’s obligations under any of the Leases, suffer or permit to occur any
condition which would permit any Tenant to set off, withhold or otherwise abate rent nor suffer or
permit the same to terminate by reason of any failure of Borrower to meet any requirement of any
Lease including those with respect to any time limitation within which any of Borrower’s work is to
be done or the space is to be available for occupancy by the lessee. Borrower shall notify Agent
promptly in writing in the event a Tenant commits a material default under a Lease.

     (m) Agent and Lenders’ Attorneys’ Fees for Enforcement of Agreement. In case of any
default or Event of Default hereunder, Borrower (in addition to Lenders’ and Agent’s attorneys’
fees, if any, to be paid pursuant to Section 7.3) will pay Agent’s and Lenders’ attorneys’
and paralegal fees (including, without limitation, any attorney and paralegal fees and costs
incurred in connection with any litigation or bankruptcy or administrative hearing and any appeals
therefrom and any post-judgment enforcement action including, without limitation, supplementary
proceedings) in connection with the enforcement of this Agreement; without limiting the generality
of the foregoing, if at any time or times hereafter Agent or Lenders employ counsel (whether or not
any suit has been or shall be filed and whether or not other legal proceedings have been or shall
be instituted) for advice or other representation with respect to the Project, this Agreement, or
any of the other Loan Documents, or to protect, collect, lease, sell, take possession of, or
liquidate any of the Project, or to attempt to enforce any security interest or lien in any portion
of the Project, or to enforce any rights of Agent and Lenders or Borrower’s obligations hereunder,
then in any of such events all of the attorneys’ fees arising from such services, and any expenses,
costs and charges relating thereto (including fees and costs of paralegals), shall constitute an
additional liability owing by Borrower to Agent and Lenders, payable on demand.

     (n) Appraisals. Agent shall have the right to obtain a new or updated Appraisal of
the Project from time to time. Borrower shall cooperate with Agent in this regard. If the
Appraisal is obtained to comply with this Agreement or any applicable law or regulatory
requirement, or bank policy promulgated to comply therewith, or if an Event of Default exists,
Borrower shall pay for any such Appraisal upon Agent’s request.

     (o) Furnishing Information. Borrower shall deliver or cause to be delivered to Agent
with respect to Borrower quarterly financial statements within forty-five (45) days after the end
of each calendar quarter and an annual financial statement within ninety (90) days after the end of
each calendar year. All such financial statements shall be in a format approved in writing by
Agent in Agent’s sole discretion, shall be unaudited and shall be certified by OP Guarantor as
fairly presenting the Borrower’s financial condition. Each financial statement shall be certified
as true, complete and correct by its preparer and by Borrower. Borrower shall deliver to Agent
with respect to Borrower and each Guarantor annual Federal Income Tax Returns, if applicable,
within ten (10) days after timely filing if requested by Agent. In addition, thirty (30) days
prior to the opening of the Project and thereafter not later than thirty (30) days before the end
of each fiscal year of Borrower, Borrower shall deliver to Agent the Project’s updated annual
operating budget for the following fiscal year. Within thirty (30) days after completion of the
Project, and within thirty (30) days following the end of each calendar month thereafter, Borrower
shall deliver to Agent: (i) monthly unaudited operating cash flow statements for the Project,
certified as true, complete and correct by Borrower showing actual sources and uses of cash during
the preceding month, and (ii) a current rent roll and a summary of all leasing activity then taking
place with respect to the Project, particularly describing the status of all pending lease
negotiations, if any. Borrower and the Guarantors shall provide such additional financial
information

37

 

as Agent reasonably requires. Borrower shall during regular business hours permit Agent or
any of its agents or representatives to have access to and examine all of its books and records
regarding the development and operation of the Project.

     (p) Sign and Publicity. Upon Agent’s request, Borrower shall promptly erect a sign
approved in advance by Agent in a conspicuous location on the Project during the Construction
indicating that the financing for the Project is provided by Agent and Lenders. Agent and Lenders
reserve the right to publicize the making of the Loan.

     (q) Lost Note. Upon any Lender’s furnishing to Borrower an affidavit to such effect,
Borrower shall, if any Note is mutilated, destroyed, lost or stolen, deliver to such Lender, in
substitution therefor, a new note containing the same terms and conditions as such Note.

     (r) Indemnification. Borrower shall indemnify Agent and each Lender, including each
party owning an interest in the Loan and their respective officers, directors, employees and
consultants (each, an “Indemnified Party”) and defend and hold each Indemnified Party harmless from
and against all claims, injury, damage, loss and liability, cost and expense (including attorneys’
fees, costs and expenses) of any and every kind to any persons or property by reason of (i) the
Construction; (ii) the operation or maintenance of the Project; (iii) any breach of representation
or warranty, default or Event of Default; or (iv) any other matter arising in connection with the
Loan, Borrower, Guarantor, any Tenant, or the Project, including without limitation, any mortgage,
recording or intangible taxes and any penalties. No Indemnified Party shall be entitled to be
indemnified against its own gross negligence or willful misconduct. The foregoing indemnification
shall survive repayment of the Loan and shall continue to benefit each Lender following any
assignment of the Loan with respect to matters arising or accruing prior to such assignment.

     (s) No Additional Debt. Except for the Loan, Borrower shall not incur any
Indebtedness (whether personal or nonrecourse, secured or unsecured).

     (t) Compliance With Laws. Borrower shall comply with all applicable requirements
(including applicable Laws) of any Governmental Authority having jurisdiction over Borrower or the
Project including, without limitation, all licenses and permits required by applicable laws and
regulations for the conduct of its business or the development, ownership, use or operation of the
Project.

     (u) Organizational Documents. Borrower shall not, without the prior written consent
of Agent, permit or suffer (i) a material amendment or modification of its organizational
documents, (ii) the admission of any new member, partner or shareholder (except that provided no
default or Event of Default has occurred and is continuing, OP Guarantor may transfer to a Person
approved by Agent, such approval not to be unreasonably withheld, up to 49% of the membership
interests in Borrower, provided that no Change of Control occurs, or (iii) any dissolution or
termination of its existence.

     (v) Furnishing Reports. Upon Agent’s request, Borrower shall provide Agent with
copies of all inspections, reports, test results and other information received by Borrower, which
in any way relate to the Project or any part thereof.

     (w) Management Contracts. Borrower shall not enter into, modify, amend, terminate or
cancel any management contracts for the Project or agreements with agents or brokers, without the
prior written approval of Agent, not to be unreasonably withheld. Agent hereby approves the
Management Agreement between Borrower and Republic Property TRS LLC.

     (x) Furnishing Notices. Borrower shall provide Agent with copies of all default
notices pertaining to the Project received by Borrower from any Tenant, and any material notices
pertaining to the Project from any Governmental Authority or insurance company, in each case within
seven (7) days after such notice is received.

     (y) Construction Contracts. Borrower shall not enter into, modify, amend, terminate
or cancel any contracts for the Construction, without the prior written approval of Agent, which
approval shall not be

38

 

unreasonably withheld (provided that Agent’s prior consent shall not be required for any
contract to perform Tenant Work). Borrower will furnish Agent promptly after execution thereof
executed copies of all contracts between Borrower, architects, engineers and contractors and all
subcontracts between the General Contractor or contractors and all of their subcontractors and
suppliers, which contracts and subcontracts may not have been furnished pursuant to Section
9.1(a) at the time of the Opening of the Loan.

     (z) Correction of Defects. Within five (5) days after Borrower acquires knowledge of
or receives notice of a defect in the Improvements or any departure from the Plans and
Specifications, or any other requirement of this Agreement, Borrower will commence, and thereafter
proceed with diligence to correct all such defects and departures.

     (aa) Hold Disbursements in Trust. Borrower shall receive and hold in trust for the
sole benefit of Lenders (and not for the benefit of any other person, including, but not limited
to, contractors or any subcontractors) all advances made hereunder directly to Borrower, for the
purpose of paying or reimbursing costs of the Construction in accordance with the Budget. Borrower
shall use the proceeds of the Loan solely for the payment of costs as specified in the Budget.
Borrower will pay all other costs, expenses and fees relating to the acquisition, equipping, use
and operation of the Project.

     (bb) [Intentionally Omitted.]

     (cc) Alterations. Without the prior written consent of Agent, Borrower shall not make
any material alterations to the Project (other than completion of the Construction in accordance
with the Plans and Specifications and Tenant Work in accordance with this Agreement).

     (dd) Cash Distributions. Borrower shall not make any distributions to partners,
members or shareholders, provided that after completion of Construction and achievement of
breakeven operations Borrower may distribute Net Operating Income not needed to pay amounts payable
under the Loan Documents or other operating expenses so long as no Event of Default exists or would
arise as a result thereof.

     (ee) Compliance. The Borrower shall comply with all agreements and instruments to
which it is a party, or by which it or any of its properties may be bound.

     (ff) Notices.

          (i) Notice of Litigation and Judgments. The Borrower and the Guarantors will give
notice to the Agent in writing within fifteen (15) days of becoming aware of any litigation or
proceedings threatened in writing or any pending litigation and proceedings affecting the Project
or affecting Borrower or a Guarantor or to which any of such Persons is to become a party involving
an uninsured claim against any of such Persons that could reasonably be expected to have a
materially adverse effect on such Person and stating the nature and status of such litigation or
proceedings; and

          (ii) Defaults. The Borrower and the Guarantors will promptly notify the Agent in
writing of the occurrence of any default or Event of Default, specifying the nature and existence
of such default or Event of Default and what action the Borrower or applicable Guarantor is taking
or propose to take with respect thereto.

     (gg) Registered Servicemark. The Project shall not be owned or operated by the
Borrower under any registered or protected trademark, tradename, servicemark or logo.

     (hh) Restrictions on Easements, Covenants and Restrictions. After the date of this
Agreement, the Borrower will not create or suffer to be created or to exist any easement, right of
way, restriction, covenant, condition, license or other right in favor of any Person which affects
or might affect title to the Project or the use and occupancy of the Project or any part thereof
without (i) submitting to the Agent the proposed instrument creating such easement, right of way,
covenant, condition, license or other right, accompanied by a survey showing the exact proposed
location thereof and such other information as the Agent may reasonably request, and (ii) obtaining
the prior approval of the Agent, which approval shall not be unreasonably withheld.

39

 

     (ii) Merger. Borrower will not become a party to any merger, consolidation or other
business combination, or agree to or effect any asset acquisition or stock acquisition or other
acquisition of beneficial or legal ownership interests. Borrower shall not sell all or
substantially all of its assets except in the event the Obligations are paid in full and the
obligations of the Lenders hereunder terminate in connection therewith.

     (jj) Additional Covenants with Respect to Operations. Notwithstanding anything in
this Agreement to the contrary, Borrower represents, warrants and covenants as of the date hereof
and until such time as the Obligations are paid in full that Borrower:

          (i) does not own and will not own any asset other than the Project, and such incidental
personal property as such Borrower considers necessary, advisable, convenient or appropriate in
connection with the ownership of such assets; and

          (ii) is not engaged and will not engage in any business other than the ownership and operation
and sale of its assets described in (jj)(i).

     (kk) Letters of Credit. Borrower shall transfer any letter of credit provided by a
Tenant as a security deposit or other security under a Lease to Agent, designating Agent as
beneficiary under such letter of credit. Agent agrees that any such letter of credit shall be
drawn by Agent only upon compliance with the conditions set forth in the applicable Lease for
application to the tenant’s security deposit. In the event that Borrower is entitled under the
applicable Lease to draw on any such letter of credit, Borrower shall promptly notify Agent. Agent
shall have no obligation to determine whether or when Borrower may be entitled to make a draw on
such letter of credit. Agent may then submit a draw on such letter of credit, or alternatively
Agent may transfer such letter of credit to Borrower for the purposes of Borrower making a draw on
such letter of credit. So long as no Event of Default has occurred and is continuing, any funds
paid under such letter of credit shall be deposited with the Agent as additional equity and be
deemed contributed to the line item in the Budget for Tenant Work, tenant allowances and leasing
commissions, and may be disbursed as provided in this Agreement. Upon the occurrence and during
the continuation of an Event of Default, Agent shall have the right, but not the obligation, to
disburse and apply any such funds paid under any such letter of credit to the Obligations in such
order as Agent may determine.

15.2 Authorized Representative.

     Borrower hereby appoints Gary R. Siegel, Mike Green and Mark Keller, any of whom may act, as
its Authorized Representative for purposes of dealing with Agent and Lenders on behalf of Borrower
in respect of any and all matters in connection with this Agreement, the other Loan Documents, and
the Loan. The Authorized Representative shall have the power, in his discretion, to give and
receive all notices, monies, approvals, and other documents and instruments, and to take another
action on behalf of Borrower. All actions by the Authorized Representative shall be final and
binding on Borrower. Agent and Lenders may rely on the authority given to the Authorized
Representative until actual receipt by Agent of a duly authorized resolution substituting a
different person as the Authorized Representative.

ARTICLE 16

CASUALTIES AND CONDEMNATION

16.1 Agent’s Election to Apply Proceeds on Indebtedness.

     (a) Subject to the provisions of Section 16.1(b) below, Agent may elect to collect,
retain and apply upon the indebtedness of Borrower under this Agreement or any of the other Loan
Documents all proceeds of insurance or condemnation (individually and collectively referred to as
“Proceeds”) after deduction of all expenses of collection and settlement, including
attorneys’ and adjusters’ fees and charges. Any proceeds remaining after repayment of the
indebtedness under the Loan Documents shall be paid by Agent to Borrower.

     (b) Borrower hereby irrevocably authorizes and empowers Agent, at Agent’s option and in
Agent’s sole discretion, as attorney in fact for Borrower, to make proof of such loss, to adjust
and compromise any claim under insurance policies, to appear in and prosecute any action arising
from such insurance policies, to collect and

40

 

receive insurance proceeds, and to deduct therefrom Agent’s expenses incurred in the
collection of such proceeds. Borrower authorizes Agent, at Agent’s option (but in no event shall
Agent be obligated to), as attorney in fact for Borrower, to commence, appear in and prosecute, in
Agent or Borrower’s name, any action or proceeding relating to any Taking of the Project and to
settle or compromise any claim in connection with such Taking. Borrower may not settle, adjust or
compromise any casualty or Taking without the prior written consent of the Agent, which consent
shall not be unreasonably withheld or delayed. Notwithstanding anything in Section 16.1(a)
to the contrary, in the event of any casualty to the Improvements or any condemnation of part of
the Project, Agent agrees to make available the Proceeds to restoration of the Improvements if (i)
no Event of Default exists, (ii) all Proceeds are deposited with Agent, (iii) in Agent’s reasonable
judgment, the amount of Proceeds available for restoration of the Improvements (together with
undisbursed proceeds of the Loan, if any, allocated for the cost of the Construction and any sums
or other security acceptable to Agent deposited with Agent by Borrower for such purpose) is
sufficient to pay the full and complete costs of such restoration, (iv) no Leases in effect at the
time of such casualty or Taking are or will be terminated or rent decreased as a result of such
casualty or Taking, (v) if the cost of restoration exceeds ten percent (10%) of the Loan Amount, in
Agent’s sole determination after completion of restoration the Loan Amount will not exceed 70% of
the fair market value of the Project, (vi) in Agent’s reasonable determination, the Project can be
restored to an architecturally and economically viable project in compliance with applicable Laws,
(vii) each Guarantor reaffirms the Guaranty in writing, and (viii) in Agent’s reasonable
determination, such restoration is likely to be completed not later than three months prior to the
Maturity Date.

16.2 Borrower’s Obligation to Rebuild and Use of Proceeds Therefor.

     In case Agent does not elect to apply or does not have the right to apply the Proceeds to the
indebtedness, as provided in Section 16.1 above, Borrower shall:

     (a) Proceed with diligence to make settlement with insurers or the appropriate Governmental
Authorities and cause the Proceeds to be deposited with Agent;

     (b) In the event of any delay in making settlement with insurers or the appropriate
Governmental Authorities or effecting collection of the Proceeds, deposit with Agent the full
amount required to complete construction as aforesaid;

     (c) In the event the Proceeds and the available proceeds of the Loan are insufficient to
assure the Agent that the Loan will be In Balance, promptly deposit with Agent any amount necessary
to place the Loan In Balance; and

     (d) Promptly proceed with the resumption of construction of the Improvements, including the
repair of all damage resulting from such fire, condemnation or other cause and restoration to its
former condition.

     Any request by Borrower for a disbursement by Agent of Proceeds and funds deposited by
Borrower shall be treated by Agent as if such request were for an advance of the Loan hereunder,
and the disbursement thereof shall be conditioned upon Borrower’s compliance with and satisfaction
of the same conditions precedent as would be applicable under this Agreement for an advance of the
Loan.

ARTICLE 17

ASSIGNMENTS BY LENDERS AND BORROWER

17.1 Prohibition of Assignments and Transfers by Borrower.

     Borrower shall not assign or attempt to assign its rights under this Agreement and any
purported assignment shall be void. Without the prior written consent of Agent, in Agent’s sole
discretion, Borrower shall not suffer or permit (a) any change in the management (whether direct or
indirect) of the Project or of Borrower, or (b) any Transfer (provided that so long as no Event of
Default has occurred and is continuing, OP Guarantor may transfer to a Person up to 49% of the
membership interests in Borrower provided that such Transfer does not result in a Change of
Control). Notwithstanding the foregoing, any Transfer of ownership interests in Parent Guarantor
or

41

 

OP Guarantor shall not cause a violation of this Section 17.1 so long as such Transfer
does not result in a Change of Control.

17.2 Prohibition of Transfers in Violation of ERISA.

     In addition to the prohibitions set forth in Section 17.1 above, Borrower shall not
assign, sell, pledge, encumber, transfer, hypothecate or otherwise dispose of its interest or
rights in this Agreement or in the Project, or attempt to do any of the foregoing or suffer any of
the foregoing, nor shall any party owning a direct or indirect interest in Borrower assign, sell,
pledge, mortgage, encumber, transfer, hypothecate or otherwise dispose of any of its rights or
interest (direct or indirect) in Borrower, attempt to do any of the foregoing or suffer any of the
foregoing, if such action would cause the Loan, or the exercise of any of Agent’s or Lenders’
rights in connection therewith, to constitute a prohibited transaction under ERISA or the Internal
Revenue Code or otherwise result in Agent or any Lender being deemed in violation of any applicable
provision of ERISA. Borrower agrees to indemnify and hold Agent and each Lender free and harmless
from and against all losses, costs (including attorneys’ fees and expenses), taxes, damages
(including consequential damages) and expenses Agent or such Lender may suffer by reason of the
investigation, defense and settlement of claims and in obtaining any prohibited transaction
exemption under ERISA necessary or desirable in Agent or any Lender’s sole judgment or by reason of
a breach of the foregoing prohibitions. The foregoing indemnification shall be a recourse
obligation of Borrower and shall survive repayment of the Notes, notwithstanding any limitations on
recourse contained herein or in any of the Loan Documents.

17.3 Successors and Assigns.

     Subject to the foregoing restrictions on transfer and assignment contained in this Article
17, this Agreement shall inure to the benefit of and shall be binding on the parties hereto and
their respective successors and permitted assigns.

ARTICLE 18

TIME OF THE ESSENCE

18.1 Time is of the Essence.

     Borrower agrees that time is of the essence under this Agreement.

ARTICLE 19

EVENTS OF DEFAULT

     The occurrence of any one or more of the following shall constitute an “Event of
Default” as said term is used herein:

     (a) Failure of Borrower (i) (A) to make any principal payment when due (including without
limitation the obligation under Section 4.1(e)), (B) to pay any interest within five (5)
days after the date when due or (C) to observe or perform any of the other covenants or conditions
by Borrower to be performed under the terms of this Agreement or any other Loan Document concerning
the payment of money, for a period of ten (10) days after written notice from Agent that the same
is due and payable; or (ii) for a period of thirty (30) days after written notice from Agent, to
observe or perform any non-monetary covenant or condition contained in this Agreement or any other
Loan Documents, or if such failure is of such a nature that it cannot be cured within such thirty
(30) day period but such failure is of a nature that it is capable of being cured, in the event
that Borrower in good faith promptly commences such cure within such thirty (30) day period and
thereafter diligently, continuously and in good faith prosecutes such cure to completion, such
period shall be extended for an additional thirty (30) days provided that such extended cure period
shall not in Lender’s judgment cause any delays in Construction, cause a default under a Lease or
result in a Material Adverse Change; and provided further that if a different notice or grace
period is specified under any other subsection of this Section 19.1 with respect to a
particular breach, or if another subsection of this Section 19.1 applies to a particular
breach and does not expressly provide for a notice or grace period the specific provision shall
control; provided, however, that if a different notice or grace period or no notice
and cure

42

 

period is specified under Article 19 of the Loan Agreement (or elsewhere in the Loan Agreement
or any other Loan Document) in which such particular breach will become an Event of Default, the
specific provision shall control.

     (b) The disapproval by Agent or Lender’s Consultant at any time of any construction work and
failure of Borrower to cause the same to be corrected to the satisfaction of Agent within the cure
period provided in Section 19.1(a)(ii) above.

     (c) A delay in the Construction or a discontinuance for a period of thirty (30) days after
written notice from Agent concerning such delay or discontinuance (other than Unavoidable Delays),
or in any event a delay in the Construction so that the same is not, in Agent’s judgment (giving
due consideration to the assessment of Lender’s Consultant), likely to be completed on or before
the Completion Date.

     (d) The bankruptcy or insolvency of General Contractor and failure of Borrower to procure a
contract with a new contractor satisfactory to Agent within thirty (30) days from the occurrence of
such bankruptcy or insolvency.

     (e) Any Transfer or other disposition in violation of Sections 17.1 or 17.2;
provided, however, no cure period shall be available to Borrower upon any such
occurrence.

     (f) [Intentionally Omitted.]

     (g) If any warranty, representation, statement, report or certificate made now or hereafter by
Borrower or any Guarantor is untrue or incorrect in any material manner at the time made, delivered
or repeated.

     (h) Borrower or any Guarantor shall commence a voluntary case concerning Borrower or such
Guarantor under the Bankruptcy Code; or an involuntary proceeding is commenced against Borrower or
any Guarantor under the Bankruptcy Code and relief is ordered against Borrower or such Guarantor,
or the petition is controverted but not dismissed or stayed within sixty (60) days after the
commencement of the case, or a custodian (as defined in the Bankruptcy Code) is appointed for or
takes charge of all or substantially all of the property of Borrower or any Guarantor; or the
Borrower or any Guarantor commences any other proceedings under any reorganization, arrangement,
readjustment of debt, relief of debtors, dissolution, insolvency or liquidation or similar Law of
any jurisdiction whether now or hereafter in effect relating to the Borrower or any Guarantor; or
there is commenced against Borrower or any Guarantor any such proceeding which remains undismissed
or unstayed for a period of sixty (60) days; or the Borrower or any Guarantor fails to controvert
in a timely manner any such case under the Bankruptcy Code or any such proceeding, or any order of
relief or other order approving any such case or proceeding is entered; or the Borrower or any
Guarantor by any act or failure to act indicates its consent to, approval of, or acquiescence in
any such case or proceeding or the appointment of any custodian or the like of or for it for any
substantial part of its property or suffers any such appointment to continue undischarged or
unstayed for a period of sixty (60) days.

     (i) Borrower or any Guarantor shall make an assignment for the benefit of creditors, or shall
admit in writing its inability to pay its debts generally as they become due, or shall consent to
the appointment of a receiver or trustee or liquidator of all of its property or the major part
thereof or if all or a substantial part of the assets of Borrower or any Guarantor are attached,
seized, subjected to a writ or distress warrant, or are levied upon, or come into the possession of
any receiver, trustee, custodian or assignee for the benefit of creditors.

     (j) If Borrower is permanently or temporarily (for a period of thirty (30) days or more)
enjoined, restrained or in any way prevented by any court order from constructing or operating the
Project.

     (k) Failure by Borrower to make any Deficiency Deposit with Agent within the time and in the
manner required by Article 11 hereof.

     (l) One or more final, unappealable judgments are entered (i) against Borrower in amounts
aggregating in excess of $100,000 or (ii) against any Guarantor in amounts aggregating in excess of
$10,000,000, and said judgments are not stayed or bonded over within thirty (30) days after entry.

43

 

     (m) An “Event of Default” (as defined in the OP Credit Agreement) shall occur.

     (n) If a Material Adverse Change occurs with respect to Borrower, the Project or any
Guarantor.

     (o) The occurrence of a Change of Control.

     (p) The occurrence of any other event or circumstance denominated as an Event of Default in
this Agreement or under any of the other Loan Documents and the expiration of any applicable grace
or cure periods, if any, specified for such Event of Default herein or therein, as the case may be.

ARTICLE 20

LENDERS’ REMEDIES IN EVENT OF DEFAULT

20.1 Remedies Conferred Upon Lenders.

     Upon the occurrence of any Event of Default, Agent may, and at the request of the Required
Lenders shall, pursue any one or more of the following remedies concurrently or successively, it
being the intent hereof that none of such remedies shall be to the exclusion of any other:

     (a) Take possession of the Project and complete the Construction and do anything which is
necessary or appropriate in its sole judgment to fulfill the obligations of Borrower under this
Agreement and the other Loan Documents, including either the right to avail itself of and procure
performance of existing contracts or let any contracts with the same contractors or others.
Without restricting the generality of the foregoing and for the purposes aforesaid, Borrower hereby
appoints and constitutes Agent its lawful attorney in fact with full power of substitution in the
Project to complete the Construction in the name of Borrower; to use unadvanced funds remaining
under the Notes or which may be reserved, escrowed or set aside for any purposes hereunder at any
time, or to advance funds in excess of the face amount of the Notes, to complete the Construction;
to make changes in the Plans and Specifications which shall be necessary or desirable to complete
the Construction in substantially the manner contemplated by the Plans and Specifications; to
retain or employ new general contractors, subcontractors, architects, engineers and inspectors as
shall be required for said purposes; to pay, settle or compromise all existing bills and claims,
which may be liens or security interests, or to avoid such bills and claims becoming liens against
the Project; to execute all applications and certificates in the name of Borrower prosecute and
defend all actions or proceedings in connection with the Improvements or Project; to take action
and require such performance as it deems necessary under any of the Bonds to be furnished hereunder
and to make settlements and compromises with the surety or sureties thereunder, and in connection
therewith, to execute instruments of release and satisfaction; and to do any and every act which
the Borrower might do in its own behalf; it being understood and agreed that this power of attorney
shall be a power coupled with an interest and cannot be revoked;

     (b) Withhold further disbursement of the proceeds of the Loan and/or terminate Lenders’
obligations to make further disbursements hereunder;

     (c) Declare the Notes to be immediately due and payable;

     (d) Use and apply any monies or letters of credit deposited by Borrower with Agent or Lenders
regardless of the purposes for which the same was deposited, to cure any such default or to apply
on account of any indebtedness under this Agreement which is due and owing to Agent and Lenders;

     (e) Exercise or pursue any other remedy or cause of action permitted under this Agreement or
any other Loan Documents, or conferred upon Agent or Lenders by operation of Law.

     Notwithstanding the foregoing, upon the occurrence of any Event of Default under
Section 19.1(h) with respect to the Borrower, all amounts evidenced by the Notes shall
automatically become due and payable, without any presentment, demand, protest or notice of any
kind to Borrower.

44

 

ARTICLE 21

GENERAL PROVISIONS

21.1 Captions.

     The captions and headings of various Articles, Sections and subsections of this Agreement and
Exhibits pertaining hereto are for convenience only and are not to be considered as defining or
limiting in any way the scope or intent of the provisions hereof.

21.2 Modification; Waiver.

     Subject to the provisions of Section 25.6 herein, no modification, waiver, amendment
or discharge of this Agreement or any other Loan Document shall be valid unless the same is in
writing and signed by the party against which the enforcement of such modification, waiver,
amendment or discharge is sought. The Borrower agrees to enter into (and to cause Guarantors to
enter into) such modifications or amendments of this Agreement or the other Loan Documents as
reasonably may be requested by Agent in connection with the syndication of the Loan, provided that
no such amendment or modification materially affects or increases any of the obligations of the
Borrower or Guarantors hereunder or thereunder.

21.3 Governing Law.

     Irrespective of the place of execution and/or delivery, this Agreement shall be governed by,
and shall be construed in accordance with, the laws of the District of Columbia.

21.4 Acquiescence Not to Constitute Waiver of Lenders’ Requirements.

     Each and every covenant and condition for the benefit of Lenders and Agent contained in this
Agreement may be waived by Agent, Lenders or the Required Lenders as provided herein, provided,
however, that to the extent that Agent or any Lender may have acquiesced in any noncompliance with
any construction or nonconstruction conditions precedent to the Opening of the Loan or to any
subsequent disbursement of Loan proceeds, such acquiescence shall not be deemed to constitute a
waiver by Agent or any Lender of such requirements with respect to any future disbursements of Loan
proceeds.

21.5 Disclaimer by Lenders.

     This Agreement is made for the sole benefit of Borrower and Lenders, and no other person or
persons shall have any benefits, rights or remedies under or by reason of this Agreement, or by
reason of any actions taken by Lenders pursuant to this Agreement. Lenders shall not be liable to
any contractors, subcontractors, supplier, architect, engineer, tenant or other party for labor or
services performed or materials supplied in connection with the Construction. Lenders shall not be
liable for any debts or claims accruing in favor of any such parties against Borrower or others or
against the Project. Lenders, by making the Loan or taking any action pursuant to any of the Loan
Documents, shall not be deemed a partner or a joint venturer with Borrower or fiduciary of
Borrower. No payment of funds directly to a contractor or subcontractor or provider of services
shall be deemed to create any third party beneficiary status or recognition of same by the Lenders.
Without limiting the generality of the foregoing:

     (a) Lenders shall have no liability, obligation or responsibility whatsoever with respect to
the Construction. Any inspections of the Construction made by or through Lenders are for purposes
of administration of the Loan only and neither Borrower nor any third party is entitled to rely
upon the same with respect to the quality, adequacy or suitability of materials or workmanship,
conformity to the Plans and Specifications, state of completion or otherwise;

     (b) Lenders neither undertake nor assume any responsibility or duty to Borrower to select,
review, inspect, supervise, pass judgment upon or inform Borrower of any matter in connection with
the Project, including
matters relating to the quality, adequacy or suitability of: (i) the Plans and
Specifications, (ii) architects, contractors,

45

 

subcontractors and material suppliers employed or
utilized in connection with the Construction, or the workmanship of or the materials used by any of
them, or (iii) the progress or course of Construction and its conformity or nonconformity with the
Plans and Specifications; Borrower shall rely entirely upon its own judgment with respect to such
matters, and any review, inspection, supervision, exercise of judgment or supply of information to
Borrower by Lenders in connection with such matters is for the protection of Lenders only, and
neither Borrower nor any third party is entitled to rely thereon; and

     (c) Lenders owe no duty of care to protect Borrower, any Guarantor or any Tenant against
negligent, faulty, inadequate or defective building or construction.

     Notwithstanding anything herein to the contrary, each reference in this Section 21.5
to Lenders shall also be deemed to refer to Agent.

21.6 Partial Invalidity; Severability.

     If any of the provisions of this Agreement, or the application thereof to any person, party or
circumstances, shall, to any extent, be invalid or unenforceable, the remainder of this Agreement,
or the application of such provision or provisions to persons, parties or circumstances other than
those as to whom or which it is held invalid or unenforceable, shall not be affected thereby, and
every provision of this Agreement shall be valid and enforceable to the fullest extent permitted by
law.

21.7 Definitions Include Amendments.

     Definitions contained in this Agreement which identify documents, including, but not limited
to, the Loan Documents, shall be deemed to include all amendments and supplements to such documents
from the date hereof, and all future amendments, modifications, and supplements thereto entered
into from time to time to satisfy the requirements of this Agreement or otherwise with the consent
of Agent (and, to the extent applicable, the Required Lenders). Reference to this Agreement
contained in any of the foregoing documents shall be deemed to include all amendments and
supplements to this Agreement.

21.8 Execution in Counterparts.

     This Agreement may be executed in any number of counterparts and by different parties hereto
in separate counterparts, each of which when so executed shall be deemed to be an original and all
of which taken together shall constitute one and the same agreement.

21.9 Entire Agreement.

     This Agreement, taken together with all of the other Loan Documents and all certificates and
other documents delivered by Borrower to Agent or Lenders, embody the entire agreement and
supersede all prior agreements, written or oral, relating to the subject matter hereof.

21.10 Waiver of Damages.

     In no event shall Lenders or Agent be liable to Borrower for punitive, exemplary or
consequential damages, including, without limitation, lost profits, whatever the nature of a breach
by any Lender or Agent of its obligations under this Agreement or any of the Loan Documents, and
Borrower for itself and Guarantors waive all claims for punitive, exemplary or consequential
damages.

21.11 Claims Against Agent or Lenders.

     Agent and Lenders shall not be in default under this Agreement, or under any other Loan
Documents, unless a written notice specifically setting forth the claim of Borrower shall have been
given to Agent within three (3) months after Borrower first had knowledge of the occurrence of the
event which Borrower alleges gave rise to
such claim and Agent or such Lender, as applicable, does not remedy or cure the default, if
any there be, promptly

46

 

thereafter. Borrower waives any claim, set-off or defense against Agent and
Lenders arising by reason of any alleged default by Agent or Lenders as to which Borrower does not
give such notice timely as aforesaid. Borrower acknowledges that such waiver is or may be
essential to Agent’s and Lenders’ ability to enforce its remedies without delay and that such
waiver therefore constitutes a substantial part of the bargain between Agent, Lenders and Borrower
with regard to the Loan. No Guarantor or Tenant is intended to have any rights as a third-party
beneficiary of the provisions of this Section 21.11.

21.12 Jurisdiction.

     TO THE GREATEST EXTENT PERMITTED BY LAW, BORROWER HEREBY WAIVES ANY AND ALL RIGHTS TO REQUIRE
MARSHALLING OF ASSETS BY AGENT AND LENDERS. WITH RESPECT TO ANY SUIT, ACTION OR PROCEEDINGS
RELATING TO THIS AGREEMENT (EACH, A “PROCEEDING”), BORROWER IRREVOCABLY (A) SUBMITS TO THE
NON-EXCLUSIVE JURISDICTION OF THE LOCAL AND FEDERAL COURTS HAVING JURISDICTION IN THE DISTRICT OF
COLUMBIA, AND (B) WAIVES ANY OBJECTION WHICH IT MAY HAVE AT ANY TIME TO THE LAYING OF VENUE OF ANY
PROCEEDING BROUGHT IN ANY SUCH COURT, WAIVES ANY CLAIM THAT ANY PROCEEDING HAS BEEN BROUGHT IN AN
INCONVENIENT FORUM AND FURTHER WAIVES THE RIGHT TO OBJECT, WITH RESPECT TO SUCH PROCEEDING, THAT
SUCH COURT DOES NOT HAVE JURISDICTION OVER SUCH PARTY. NOTHING IN THIS AGREEMENT SHALL PRECLUDE
AGENT OR LENDERS FROM BRINGING A PROCEEDING IN ANY OTHER JURISDICTION NOR WILL THE BRINGING OF A
PROCEEDING IN ANY ONE OR MORE JURISDICTIONS PRECLUDE THE BRINGING OF A PROCEEDING IN ANY OTHER
JURISDICTION. BORROWER FURTHER AGREES AND CONSENTS THAT, IN ADDITION TO ANY METHODS OF SERVICE OF
PROCESS PROVIDED FOR UNDER APPLICABLE LAW, ALL SERVICE OF PROCESS IN ANY PROCEEDING IN ANY LOCAL OR
UNITED STATES COURT SITTING IN THE DISTRICT OF COLUMBIA MAY BE MADE BY CERTIFIED OR REGISTERED
MAIL, RETURN RECEIPT REQUESTED, DIRECTED TO BORROWER AT THE ADDRESS INDICATED BELOW, AND SERVICE SO
MADE SHALL BE COMPLETE UPON RECEIPT; EXCEPT THAT IF BORROWER SHALL REFUSE TO ACCEPT DELIVERY,
SERVICE SHALL BE DEEMED COMPLETE FIVE (5) DAYS AFTER THE SAME SHALL HAVE BEEN SO MAILED.

21.13 Set-Offs.

     After the occurrence and during the continuance of an Event of Default, Borrower hereby
irrevocably authorizes and directs Lenders from time to time to charge Borrower’s accounts and
deposits with such Lender (or its Affiliates), and to pay over to such Lender an amount equal to
any amounts from time to time due and payable to such Lender hereunder, under the Notes or under
any other Loan Document; provided that no Lender shall exercise its right of set-off under this
Section without the prior written approval of Agent. Borrower hereby grants to Lenders a security
interest in and to all such accounts and deposits maintained by the Borrower with Lenders (or their
Affiliates).

21.14 Distribution of Collateral Proceeds.

     In the event that, following the occurrence and during the continuance of any Event of
Default, any monies are received in connection with the enforcement of any of the Loan Documents,
or otherwise with respect to the realization upon any of the Collateral or other assets of Borrower
or the Guarantors, such monies shall be distributed for application as follows:

     (a) First, to the payment of, or (as the case may be) the reimbursement of the Agent for or in
respect of, all reasonable out-of-pocket costs, expenses, disbursements and losses which shall have
been paid, incurred or sustained by the Agent to protect or preserve the Collateral or in
connection with the collection of such monies by the Agent, for the exercise, protection or
enforcement by the Agent of all or any of the rights, remedies, powers and privileges of the Agent
or the Lenders under this Agreement or any of the other Loan Documents or in respect of the
Collateral or in support of any provision of adequate indemnity to the Agent against any taxes or
liens which by law shall have, or may have, priority over the rights of the Agent or the Lenders to
such monies;

47

 

     (b) Second, to all other Obligations (including any interest, expenses or other obligations
incurred after the commencement of a bankruptcy) in such order or preference as the Required
Lenders shall determine; provided, that (i) distributions in respect of such other Obligations
shall include, on a pari passu basis, the Agent’s fee payable pursuant to Section 7.2; (ii)
in the event that any Lender shall have wrongfully failed or refused to make an advance under
Section 25.4 and such failure or refusal shall be continuing, advances made by other
Lenders during the pendency of such failure or refusal shall be entitled to be repaid as to
principal and accrued interest in priority to the other Obligations described in this subsection
(b), and (iii) except as otherwise provided in clause (ii), Obligations owing to the Lenders with
respect to each type of Obligation such as interest, principal, fees and expenses shall be made
among the Lenders pro rata; and provided, further that the Required Lenders may in
their discretion make proper allowance to take into account any Obligations not then due and
payable; and

     (c) Third, the excess, if any, shall be returned to the Borrower or to such other Persons as
are entitled thereto.

ARTICLE 22

NOTICES

     Each notice, demand, election or request provided for or permitted to be given pursuant to
this Agreement (hereinafter in this Article 22 referred to as “Notice”), but specifically excluding
to the maximum extent permitted by law any notices of the institution or commencement of
foreclosure proceedings, must be in writing and shall be deemed to have been properly given or
served by personal delivery or by sending same by overnight courier or by depositing same in the
United States Mail, postpaid and registered or certified, return receipt requested, or as expressly
permitted herein, by telegraph, telecopy, telefax or telex, and addressed as follows:

     If to Borrower:

Republic 20th Street LLC

13861 Sunrise Valley Drive, Suite 410

Herndon, Virginia 20171

Attention: Gary R. Siegel

Telephone: (703) 880-2900

Facsimile: (703) 880-2901

     With a copy to:

Glazer, Winston Honigman Ellick

5301 Wisconsin Avenue

Suite 740

Washington, DC 20015

Attention: Lori J. Honigman

Telephone: (202) 537-5500

Facsimile: (202) 537-5505

     If to Agent or KeyBank:

KeyBank National Association, as Agent

127 Public Square, 8th Floor

OH 01-27-0844

Cleveland, Ohio 44114

Attention: Michael P. Szuba

Telephone: (216) 689-5984

Facsimile: (216) 689-4997

48

 

     With a copy to:

McKenna Long & Aldridge LLP

303 Peachtree Street, N.E.; Suite 5300

Atlanta, Georgia 30308

Attention: William F. Timmons, Esq.

Telephone: (404) 527-8380

Facsimile: (404) 527-4198

to any other Lender which is a party hereto, at the address for such Lender set forth on its
signature page hereto, and to any Lender which may hereafter become a party to this Agreement, at
such address as may be designated by such Lender. Each Notice shall be effective upon being
personally delivered or upon being sent by overnight courier or upon being deposited in the United
States Mail as aforesaid, or if transmitted by telegraph, telecopy, telefax or telex is permitted,
upon being sent and confirmation of receipt. The time period in which a response to such Notice
must be given or any action taken with respect thereto (if any), however, shall commence to run
from the date of receipt if personally delivered or sent by overnight courier, or if so deposited
in the United States Mail, the earlier of three (3) Business Days following such deposit or the
date of receipt as disclosed on the return receipt. Rejection or other refusal to accept or the
inability to deliver because of changed address for which no notice was given shall be deemed to be
receipt of the Notice sent. By giving at least fifteen (15) days prior Notice thereof, the
Borrower, a Lender or Agent shall have the right from time to time and at any time during the term
of this Agreement to change their respective addresses and each shall have the right to specify as
its address any other address within the United States of America.

ARTICLE 23

WAIVER OF JURY TRIAL

     BORROWER, AGENT AND LENDERS EACH WAIVE ANY RIGHT TO A TRIAL BY JURY IN ANY ACTION OR
PROCEEDING TO ENFORCE OR DEFEND ANY RIGHTS UNDER THIS AGREEMENT AND THE OTHER LOAN DOCUMENTS OR
RELATING THERETO OR ARISING FROM THE LENDING RELATIONSHIP WHICH IS THE SUBJECT OF THIS AGREEMENT
AND AGREE THAT ANY SUCH ACTION OR PROCEEDING SHALL BE TRIED BEFORE A COURT AND NOT BEFORE A JURY.

ARTICLE 24

ASSIGNMENTS AND PARTICIPATIONS

24.1 Assignments and Participations.

     (a) Each Lender shall have the right to assign, transfer, sell, negotiate, pledge or otherwise
hypothecate this Agreement and any of its rights and security hereunder and under the other Loan
Documents to any other Eligible Assignee with the prior written consent of the Agent and with the
prior written consent of Borrower, which consents by the Agent and the Borrower shall not be
unreasonably withheld, conditioned or delayed (provided that no consent of Borrower shall be
required if the Eligible Assignee is also a Lender or if an Event of Default then exists) and no
consent of the Agent shall be required if the Eligible Assignee is also a Lender; provided,
however, that (i) the parties to each such assignment shall execute and deliver to Agent, for its
approval and acceptance, an Assignment and Assumption, (ii) each such assignment shall be of a
constant, and not a varying, percentage of the assigning Lender’s rights and obligations under this
Agreement, (iii) if the potential assignee is not already a Lender hereunder, at least ten (10)
days prior to the date of the assignment, the potential assignee shall deliver to Agent the fully
completed Patriot Act and OFAC forms attached as Exhibit M hereto and such other information as
Agent shall require to successfully complete the Agent’s Patriot Act Customer Identification
Process and OFAC Review Process, (iv) unless the Agent and, so long as no Event of Default exists,
Borrower otherwise consent, the aggregate amount of the Commitment of the assigning Lender being
assigned pursuant to each such assignment shall in no event be less than Five Million Dollars
($5,000,000) and integral multiples of One Million Dollars ($1,000,000) in excess thereof, (v) the
Agent shall receive from the assigning Lender a processing fee of Three Thousand Five Hundred
Dollars ($3,500), and (vi) if the assignment is less than the assigning Lender’s entire interest in
the Loan, the assigning Lender must retain at least a Five Million Dollar ($5,000,000) interest in
the Loan. The Agent may designate any Eligible Assignee accepting an assignment of a specified
portion of the Loan to be a Co-Agent, an

49

 

“Arranger” or similar title, but such designation shall not confer on such Assignee the rights
or duties of the Agent. Upon such execution, delivery, approval and acceptance, and upon the
effective date specified in the applicable Assignment and Assumption, (a) the Eligible Assignee
thereunder shall be a party hereto and, to the extent that rights and obligations hereunder have
been assigned to it pursuant to such Assignment and Assumption, have the rights and obligations of
a Lender hereunder and under the other Loan Documents, and Borrower hereby agrees that all of the
rights and remedies of Lenders in connection with the interest so assigned shall be enforceable
against Borrower by an Eligible Assignee with the same force and effect and to the same extent as
the same would have been enforceable but for such assignment, and (b) the assigning Lender
thereunder shall, to the extent that rights and obligations hereunder and under the other Loan
Documents have been assigned by it pursuant to such Assignment and Assumption, relinquish its
rights and be released from its obligations hereunder and thereunder.

     (b) By executing and delivering an Assignment and Assumption, the assigning Lender thereunder
and the Eligible Assignee thereunder confirm to and agree with each other and the other parties
hereto as follows: (i) except as provided in such Assignment and Assumption, such assigning Lender
and Agent make no representation or warranty and assume no responsibility with respect to any
statements, warranties or representations made in or in connection with this Agreement or any other
Loan Document or the execution, legality, validity, enforceability, genuineness, sufficiency or
value of this Agreement or any other Loan Document or any other instrument or document furnished in
connection therewith; (ii) such assigning Lender and Agent make no representation or warranty and
assume no responsibility with respect to the financial condition of the Borrower or the performance
or observance by the Borrower of any of its obligations under any Loan Document or any other
instrument or document furnished in connection therewith; (iii) such Eligible Assignee confirms
that it has received a copy of this Agreement together with such financial statements, Loan
Documents and other documents and information as it has deemed appropriate to make its own credit
analysis and decision to enter into the Assignment and Assumption and to become a Lender hereunder;
(iv) such Eligible Assignee will, independently and without reliance upon Agent, the assigning
Lender or any other Lender, and based on such documents and information as it shall deem
appropriate at the time, continue to make its own credit decisions in taking or not taking action
under this Agreement; (v) such Eligible Assignee appoints and authorizes the Agent to take such
action as the Agent on its behalf and to exercise such powers under this Agreement and the other
Loan Documents as are delegated to Agent by the terms hereof and thereof, together with such powers
as are reasonably incidental thereto; and (vi) such Eligible Assignee agrees that it will perform
in accordance with their terms all of the obligations which by the terms of this Agreement are
required to be performed by it as a Lender.

     (c) Agent shall maintain a copy of each Assignment and Assumption delivered to and accepted by
it and shall record in its records the names and address of each Lender and the Commitment of, and
Percentage of the Loan owing to, such Lender from time to time. Borrower, the Agent and Lenders
may treat each entity whose name is so recorded as a Lender hereunder for all purposes of this
Agreement. In the case of any assignment by a Lender, within five Business Days after its receipt
of such notice, the Borrower, at its own expense, shall, if requested by the applicable Lender,
execute and deliver to the Agent in exchange for the surrendered Note or Notes a new Note to the
order of such Eligible Assignee in an amount equal to the Commitment assumed by it pursuant to such
Assignment and Assumption and, if any assigning Lender has retained a Commitment hereunder, a new
Note to the order of such assigning Lender in an amount equal to the Commitment retained by it
hereunder. Such new Note or Notes, if any, shall be in an aggregate principal amount equal to the
aggregate principal amount of such surrendered Note or Notes, shall be dated the effective date of
such Assignment and Assumption and shall otherwise be in substantially the form of Exhibit C
hereto.

     (d) Upon receipt of an Assignment and Assumption executed by an assigning Lender and an
Eligible Assignee, Agent shall, if such Assignment and Assumption has been properly completed and
consented to if required herein, accept such Assignment and Assumption, and record the information
contained therein in its records, and the Agent shall use its best efforts to give prompt notice
thereof to Borrower (provided that neither the Agent nor the Lenders shall be liable for any
failure to give such notice).

     (e) Borrower shall use reasonable efforts to cooperate with Agent and each Lender in
connection with the assignment of interests under this Agreement or the sale of participations
herein but shall not be required to assume any material expense or material additional obligations
in connection therewith.

50

 

     (f) Anything in this Agreement to the contrary notwithstanding, and without the need to comply
with any of the formal or procedural requirements of this Agreement, including this Section, any
Lender may at any time and from time to time pledge and assign all or any portion of its rights
under all or any of the Loan Documents to a Federal Reserve Bank; provided that no such pledge or
assignment shall release such Lender from its obligations hereunder. To facilitate any such pledge
or assignment, the Agent shall, at the request of such Lender, enter into a letter agreement with
the Federal Reserve Bank in, or substantially in, the form of the exhibit to Appendix C to the
Federal Reserve Bank of New York Operating Circular No. 12.

     (g) Anything in this Agreement to the contrary notwithstanding, any Lender may assign all or
any portion of its rights and obligations under this Agreement to another branch or affiliate of
such Lender without first obtaining the approval of any Agent or the Borrower, provided that (i)
such Lender remains liable hereunder unless the Borrower and Agent shall otherwise agree, (ii) at
the time of such assignment such Lender is not a Defaulting Lender, (iii) such Lender gives the
Agent and Borrower at least fifteen (15) days prior written notice of any such assignment; (iv) the
parties to each such assignment execute and deliver to Agent an Assignment and Assumption, and (v)
the Agent receives from the assigning Lender a processing fee of One Thousand Five Hundred Dollars
($1,500).

     (h) Each Lender shall have the right, without the consent of the Borrower, to sell
participations to one or more Eligible Assignees in or to all or a portion of its rights and
obligations under the Loan and the Loan Documents; provided, however, that (i) such Lender’s
obligations under this Agreement (including without limitation its Commitment to Borrower
hereunder) shall remain unchanged, (ii) such Lender shall remain solely responsible to the other
parties hereto for the performance of such obligations (iii) the Borrower, the Agent and the other
Lenders shall continue to deal solely and directly with such Lender in connection with such
Lender’s rights and obligations under this Agreement and with regard to any and all payments to be
made under this Agreement and (iv) the holder of any such participation shall not be entitled to
voting rights under this Agreement or the other Loan Documents (but such holder may contract with
the Lender selling such Eligible Assignee its interest in such Lender’s share of the Loan as to
voting of such Lender’s interest under Section 25.6(b), but not under any other section of this
Agreement, provided that any such agreement by a Lender shall bind only such Lender alone and not
Borrower, the other Lenders or the Agent).

     (i) No Eligible Assignee of any rights and obligations under this Agreement shall be permitted
to subassign such rights and obligations. No participant in any rights and obligations under this
Agreement shall be permitted to sell subparticipations of such rights and obligations.

     (j) Borrower acknowledges and agrees that Lenders may provide to any Eligible Assignee or
participant originals or copies of this Agreement, any other Loan Document and any other documents,
instruments, certificates, opinions, insurance policies, letters of credit, reports, requisitions
and other materials and information of every nature or description, and may communicate all oral
information, at any time submitted by or on behalf of Borrower or received by any Lender in
connection with the Loan or with respect to Borrower, provided that prior to any such delivery or
communication, such Eligible Assignees or participants shall agree to preserve the confidentiality
of any of the foregoing to the same extent that such Lender agreed to preserve such
confidentiality. In order to facilitate assignments to Eligible Assignees and sales to Eligible
Assignees, Borrower shall execute such further documents, instruments or agreements as Lenders may
reasonably require; provided, that Borrower shall not be required (i) to execute any document or
agreement which would materially decrease its rights, or materially increase its obligations,
relative to those set forth in this Agreement or any of the other Loan Documents (including
financial obligations, personal recourse, representations and warranties and reporting
requirements), or (ii) to expend more than incidental sums of money or incidental administrative
time for which it does not receive reasonable reimbursement in order to comply with any requests or
requirements of any Lender in connection with such assignment or sale arrangement. In addition,
Borrower agrees to cooperate fully with Lenders in the exercise of Lenders’ rights pursuant to this
Section, including providing such information and documentation regarding Borrower as any Lender or
any potential Eligible Assignee or participant may reasonably request and to meet with potential
Eligible Assignees.

24.2 Several Liability.

51

 

     Anything in this Agreement contained to the contrary notwithstanding, the obligations of each
Lender to Borrower under this Agreement are several and not joint and several; each Lender shall
only be obligated to fund its Percentage of each disbursement to be made hereunder up to the amount
of its Commitment. During any time, and only during such time, as Agent is the sole Lender and has
not assigned any portion or portions of its interest in the Loan to another Lender pursuant to an
Assignment and Assumption Agreement, Agent in its individual capacity shall be liable for all of
the obligations of the Lender under this Agreement and the other Loan Documents. From and after
the date that Agent as the sole Lender assigns any portion or portions of its interest in the Loan
to another Lender pursuant to an Assignment and Assumption Agreement, then Agent shall act as the
administrative agent on behalf of itself as a Lender and the other Lenders.

ARTICLE 25

AGENT

25.1 Appointment.

     KeyBank National Association is hereby appointed as Agent hereunder and under each other Loan
Document, and each Lender hereby irrevocably authorizes the Agent to act as agent for Lenders and
to take such actions as Agent is obligated or entitled to take under the provisions of this
Agreement and the other Loan Documents. Agent agrees to act as such upon the express conditions
contained in this Article in substantially the same manner that it would act in dealing with a loan
held for its own account. The obligations of the Agent hereunder are primarily administrative in
nature, and nothing contained in this Agreement or any of the other Loan Documents shall be
construed to constitute the Agent as a trustee for any Lender or to create an agency or fiduciary
relationship. Agent shall act as the contractual representative of the Lenders hereunder, and
notwithstanding the use of the term “Agent”, it is understood and agreed that Agent shall not have
any fiduciary duties or responsibilities to any Lender by reason of this Agreement or any other
Loan Document and is acting as an independent contractor, the duties and responsibilities of which
are limited to those expressly set forth in this Agreement and the other Loan Documents.

     The provisions of this Article are solely for the benefit of the Agent and the Lenders, and
Borrower shall not have any rights to rely on or enforce any of the provisions hereof except as
provided in Sections 25.2 and 25.20 below. In performing its functions and duties under
this Agreement, the Agent shall act solely as agent of Lenders and does not assume, and shall not
be deemed to have assumed, any obligations toward or relationship of agency or trust with or for
the Borrower.

25.2 Reliance on Agent.

     All acts of and communications by the Agent, as agent for the Lenders, shall be deemed legally
conclusive and binding; and Borrower or any third party (including any court) shall rely on any and
all communications or acts of the Agent with respect to the exercise of any rights or the granting
of any consent, waiver or approval on behalf of a Lender in all circumstances where an action by
such Lender is required or permitted pursuant to this Agreement or the provisions of any other Loan
Document or by applicable law without the right or necessity of making any inquiry of any
individual Lender as to the authority of Agent with respect to such matter. In no event shall any
of the foregoing limit the rights or obligations of any Lender with respect to any other Lender
pursuant to this Article 25.

25.3 Powers.

     The Agent shall have and may exercise such powers under the Loan Documents as are specifically
delegated to the Agent by the terms of each thereof, together with such powers as are reasonably
incidental thereto or are otherwise necessary or desirable in connection with the administration of
the Loan, and may exercise all other powers of Lenders as are not made subject to the consent of
the Required Lenders pursuant to Section 25.6(a) or to the consent of all Lenders pursuant
to Section 25.6(b). Without limiting the foregoing, the Agent may consent to or execute
easements, plats, dedications, subordination and non-disturbance agreements, release of minor
portions of the collateral and similar documents. The Agent shall not be considered, or be deemed,
a separate agent of the Lenders hereunder, but is, and shall be deemed, acting in its contractual
capacity as Agent, exercising such rights and powers under the Loan Documents as are specifically
delegated to the Agent or Agent is otherwise entitled to

52

 

take hereunder. Agent shall have no implied duties to the Lenders, or any obligation to the
Lenders to take any action except any action specifically provided by the Loan Documents to be
taken by the Agent.

25.4 Disbursements.

     (a) At least one (1) Business Day (by 11:00 a.m. Cleveland time) prior to each date a
disbursement of the Loan is to be made hereunder pursuant to this Agreement (or at least two (2)
LIBOR Business Days by 11:00 a.m. Cleveland time for any disbursements to be made at the Adjusted
LIBOR Rate), the Agent shall notify each Lender of the proposed disbursement. Each Lender shall
make available to Agent (or the funding Lender or entity designated by the Agent), the amount of
such Lender’s Percentage of such disbursement (with respect to such Lender, such amount being
referred to herein as an “Advance”) in immediately available funds not later than 11:00 a.m.
(Cleveland time) on the date such disbursement is to be made (such date being referred to herein as
a “Funding Date”). Unless the Agent shall have been notified by any Lender prior to such time for
funding in respect of any Advance that such Lender does not intend to make available to the Agent
such Lender’s Advance, the Agent may assume that such Lender has made such amount available to the
Agent and the Agent, in its sole discretion, may, but shall not be obligated to, make available to
Borrower a corresponding amount. If such corresponding amount is not in fact made available to the
Agent by such Lender on or prior to the respective Funding Date, such Lender agrees to pay and
Borrower agrees to repay to Agent forthwith on demand such corresponding amount together with
interest thereon, for each day from the date such amount is made available to Borrower until the
date such amount is paid or repaid to Agent, at (A) in the case of such Lender, the Federal Funds
Effective Rate, and (B) in the case of Borrower, the interest rate applicable at the time to a
disbursement made on such Funding Date. If such Lender shall pay to Agent such corresponding
amount, such amount so paid shall constitute such Lender’s Advance, and if both such Lender and
Borrower shall have paid and repaid, respectively, such corresponding amount, Agent shall promptly
return to Borrower such corresponding amount in same day funds.

     (b) Requests by the Agent for funding by the Lenders of disbursements of the Loan will be made
by facsimile. Each Lender shall make its Advance available to the Agent in dollars and in
immediately available funds to such Lender and account as the Agent may designate, not later than
Noon (Cleveland time) on the Funding Date. Nothing in this Section 25.4 shall be deemed to
relieve any Lender of its obligation hereunder to make any Advance on any Funding Date, nor shall
any Lender be responsible for the failure of any other Lender to perform its obligations to make
any Advance hereunder, and the Commitment of any Lender shall not be increased or decreased as a
result of the failure by any other Lender to perform its obligation to make any Advances hereunder.

     (c) As soon as practical Agent will promptly forward to each Lender copies of the Draw Request
documents described in Sections 12.3(a), (b) and (d), and cause the Lender’s Consultant to
forward to each Lender a copy of the Lender’s Consultant’s most recent inspection. Delivery of the
Draw Request documents and the Lender’s Consultant’s inspection report shall not be a condition to
funding any Advance.

25.5 Distribution and Apportionment of Payments.

     (a) Subject to Section 25.5(b), payments actually received by Agent for the account of
the Lenders shall be paid to them promptly after receipt thereof by Agent, but in any event within
one (1) Business Day, provided that, if any such payments are not distributed to the Lenders within
one (1) Business Day after Agent’s receipt thereof, Agent shall pay to such Lenders interest
thereon, at the lesser of (i) the Federal Funds Effective Rate and (ii) if the applicable payment
represents repayment of a portion of the principal of the Loan, the rate of interest applicable to
such portion of the Loan, from the date of receipt of such funds by Agent until such funds are paid
in immediately available funds to such Lenders provided such funds are received by Agent not later
than 11:00 A.M. (Cleveland time) on the date of receipt. All payments of principal and interest in
respect of the Loan, all payments of the fees described in this Agreement (but not in the Agreement
Regarding Fees or any separate fee letter except to the extent expressly set forth therein), and
all payments in respect of any other obligations of Borrower under the Loan Documents shall be
allocated among such of Lenders as are entitled thereto, in proportion of their respective
Percentages or otherwise as provided herein in the other Loan Documents, as the case may be. The
Agent shall distribute to each Lender at its primary address set forth herein or in its Assignment
and Assumption, or at such other address as a Lender may request in writing, such funds as it may
be entitled to receive, provided that the Agent shall in any event not be bound to inquire into or
determine the validity, scope or priority of any interest or entitlement of any Lender and may
suspend all payments and seek appropriate relief (including without limitation

53

 

instructions from the Required Lenders, or all Lenders, as applicable, or an action in the
nature of interpleader) in the event of any doubt or dispute as to any apportionment or
distribution contemplated hereby. The order of priority herein is set forth solely to determine
the rights and priorities of the Lenders as among themselves and may at any time or from time to
time be changed by the Lenders as they may elect, in writing, without necessity of notice to or
consent of or approval by Borrower. If in the opinion of the Agent the distribution of any amount
received by it in such capacity hereunder, under the Notes or under any of the other Loan Documents
might involve it in liability, it may refrain from making such distribution until its right to make
such distribution shall have been adjudicated by a court of competent jurisdiction. If a court of
competent jurisdiction shall adjudge that any amount received and distributed by the Agent is to be
repaid, each Person to whom any such distribution shall have been made shall either repay to the
Agent its proportionate share of the amount so adjudged to be repaid or shall pay over the same in
such manner and to such Persons as shall be determined by such court.

     (b) If a Lender (a “Defaulting Lender”) defaults in making any Advance or paying any other sum
payable by it hereunder, such sum together with interest thereon at the Default Rate from the date
such amount was due until repaid (such sum and interest thereon as aforesaid referred to,
collectively, as the “Lender Default Obligation”) shall be payable by the Defaulting Lender (i) to
any Lender(s) which elect, at their sole option (and with no obligation to do so), to fund the
amount which the Defaulting Lender failed to fund or (ii) to Agent or any other Lender which under
the terms of this Agreement is entitled to reimbursement from the Defaulting Lender for the amounts
advanced or expended. Notwithstanding any provision hereof to the contrary, until such time as a
Defaulting Lender has repaid the Lender Default Obligation in full, all amounts which would
otherwise be distributed to the Defaulting Lender shall instead be applied first to repay the
Lender Default Obligation (to be applied first to interest at the Default Rate and then to
principal) until the Lender Default Obligation has been repaid in full (whether by such application
or by cure by the Defaulting Lender), whereupon such Lender shall no longer be a Defaulting Lender.
Any interest collected from Borrower on account of principal advanced by any Lender(s) on behalf
of a Defaulting Lender shall be paid to the Lender(s) who made such advance and shall be credited
against the Defaulting Lender’s obligation to pay interest on the amount advanced at the Default
Rate. If no other Lender makes an advance a Defaulting Lender failed to fund, a portion of the
indebtedness of Borrower to the Defaulting Lender equal to the Lender Default Obligation shall be
subordinated to the indebtedness of Borrower to all other Lenders and shall be paid only after the
indebtedness of Borrower to all other Lenders is paid. The provisions of this Section shall apply
and be effective regardless of whether an Event of Default occurs and is then continuing, and
notwithstanding (i) any other provision of this Agreement to the contrary or (ii) any instruction
of Borrower as to its desired application of payments. No Defaulting Lender shall have the right
to vote on matters which are subject to the consent or approval of Required Lenders or all Lenders
and while any Lender is a Defaulting Lender the requisite percentage of Lenders which constitutes
the Required Lenders shall be calculated exclusive of the Percentage of the Defaulting Lender. The
Agent shall be entitled to (i) withhold or set off, and to apply to the payment of the Lender
Default Obligation any amounts to be paid to such Defaulting Lender under this Agreement, and (ii)
bring an action or suit against such Defaulting Lender in a court of competent jurisdiction to
recover the Lender Default Obligation and, to the extent such recovery would not fully compensate
the Lenders for the Defaulting Lender’s breach of this Agreement, to collect damages. In addition,
the Defaulting Lender shall indemnify, defend and hold Agent and each of the other Lenders harmless
from and against any and all claims, actions, liabilities, damages, costs and expenses (including
attorneys’ fees and expenses), plus interest thereon at the Default Rate, for funds advanced by
Agent or any other Lender on account of the Defaulting Lender or any other damages such persons may
sustain or incur by reason of or as a direct consequence of the Defaulting Lender’s failure or
refusal to abide by its obligations under this Agreement.

     (c) At least five Business Days prior to the first date on which interest or fees are payable
hereunder for the account of any Lender, each Lender that is not incorporated under the laws of the
United States of America, or a state thereof, agrees that it will deliver to the Agent two duly
completed copies of United States Internal Revenue Service Form W-8 BEN or W-8 ECI, certifying in
either case that such Lender is entitled to receive payments under this Agreement and the Notes
without deduction or withholding of any United States federal income taxes. Each Lender which so
delivers a Form W-8 BEN or W-8 ECI further undertakes to deliver the Agent two additional copies of
such form (or a successor form) on or before the date that such form expires or becomes obsolete or
after the occurrence of any event requiring a change in the most recent forms so delivered by it,
and such amendments thereto or extensions or renewals thereof as may be reasonably requested by the
Agent, in each case certifying that such Lender is entitled to receive payments under this
Agreement and the Notes without deduction or withholding of any United States federal income taxes,
unless an event (including without limitation any change in

54

 

treaty, law or regulation) has occurred prior to the date on which any such delivery would
otherwise be required which renders all such forms inapplicable or which would prevent such Lender
from duly completing and delivering any such form with respect to it and such Lender advises the
Agent that it is not capable of receiving payments without any deduction or withholding of United
States federal income tax.

25.6 Consents and Approvals.

     (a) Each of the following shall require the approval or consent of the Required Lenders:

               (A) The exercise of any rights and remedies under the Loan Documents following an Event of
Default, provided that absent any direction from the Required Lenders, Agent may exercise any right
or remedy under the Loan Documents as Agent may determine in good faith to be necessary or
appropriate to protect the Lenders or the collateral securing the Loan;

               (B) Appointment of a successor Agent;

               (C) Approval of Post-Default Plan (defined in Section 25.7(d)); and

               (D) Except as referred to in subsection (b) below, approval of any amendment or modification
of this Agreement or any of the other Loan Documents, or issuance of any waiver of any material
provision of this Agreement or any of the other Loan Documents;

     (b) Each of the following shall require the approval or consent of all the Lenders:

               (A) Extension of the Maturity Date (beyond any extension permitted herein) or forgiveness of
all or any portion of the principal amount of the Loan or any accrued interest thereon, or any
other amendment of this Agreement or the other Loan Documents which would reduce the interest rate
or interest rate options or the rate at which fees are calculated or forgive any loan fee, or
extend the time of payment of any principal, interest or fees;

               (B) Reduction of the percentage specified in the definition of Required Lenders;

               (C) Increasing the amount of the Loan or any non-consenting Lender’s Commitment;

               (D) Release of any lien on any material collateral (except as Borrower is entitled to under
the Loan Documents);

               (E) The release or forgiveness of any Guarantor; and

               (F) Amendment of the provisions of this Section 25.6.

     (c) In addition to the required consents or approvals referred to in subsections (a)
and (b) above, the Agent may at any time request instructions from the Required Lenders
with respect to any actions or approvals which, by the terms of this Agreement or of any of the
Loan Documents, the Agent is permitted or required to take or to grant without instructions from
any Lender, and if such instructions are promptly requested, the Agent shall be absolutely entitled
to refrain from taking any action or to withhold any approval and shall not be under any liability
whatsoever for refraining from taking any action or withholding any approval under any of the Loan
Documents until it shall have received such instructions from the Required Lenders. Without
limiting the foregoing, no Lender shall have any right of action whatsoever against any Agent as a
result of such Agent acting or refraining from acting under this Agreement or any of the other Loan
Documents in accordance with the instructions of the Required Lenders or, where applicable, all
Lenders. The Agent shall promptly notify each Lender at any time that the Required Lenders have
instructed the Agent to act or refrain from acting pursuant hereto.

55

 

     (d) Each Lender authorizes and directs the Agent to enter into the Loan Documents other than
this Agreement for the benefit of the Lenders. Each Lender agrees that any action taken by the
Agent at the direction or with the consent of the Required Lenders in accordance with the
provisions of this Agreement or any other Loan Document, and the exercise by the Agent at the
direction or with the consent of the Required Lenders of the powers set forth herein or therein,
together with such other powers as are reasonably incidental thereto, shall be authorized and
binding upon all Lenders, except for actions specifically requiring the approval of all Lenders.
All communications from the Agent to the Lenders requesting Lenders’ determination, consent,
approval or disapproval (i) shall be given in the form of a written notice to each Lender, (ii)
shall be accompanied by a description of the matter or item as to which such determination,
approval, consent or disapproval is requested, or shall advise each Lender where such matter or
item may be inspected, or shall otherwise describe the matter or issue to be resolved, (iii) shall
include, if reasonably requested by a Lender and to the extent not previously provided to such
Lender, written materials and a summary of all oral information provided to the Agent by Borrower
in respect of the matter or issue to be resolved, and (iv) shall include the Agent’s recommended
course of action or determination in respect thereof. Each Lender shall reply promptly, but in any
event within ten (10) days after receipt of the request therefor from the Agent (the “Lender Reply
Period”). Unless a Lender shall give written notice to the Agent that it objects to the
recommendation or determination of the Agent (together with a written explanation of the reasons
behind such objection) within the Lender Reply Period, such Lender shall be deemed to have approved
of or consented to such recommendation or determination. With respect to decisions requiring the
approval of the Required Lenders or all Lenders, the Agent shall upon receiving the required
approval or consent follow the course of action or determination recommended to the Lenders by the
Agent or such other course of action recommended by the Required Lenders.

25.7 Agency Provisions Relating to Collateral.

     (a) The Agent is hereby authorized on behalf of all Lenders, without the necessity of any
notice to or further consent from any Lender, at any time and from time to time, to take any action
with respect to any collateral for the Loan or any Loan Document which may be necessary to preserve
and maintain such collateral or to perfect and maintain perfected the liens upon such collateral
granted pursuant to this Agreement and the other Loan Documents.

     (b) Except as provided in this Agreement, the Agent shall have no obligation whatsoever to any
Lender or to any other person or entity to assure that any collateral exists or is owned by
Borrower or is cared for, protected or insured or has been encumbered or that the liens granted
herein or in any of the other Loan Documents or pursuant hereto or thereto have been properly or
sufficiently or lawfully created, perfected, protected or enforced or are entitled to any
particular priority.

     (c) Should the Agent commence any proceeding or in any way seek to enforce the Agent’s or the
Lenders’ rights or remedies under the Loan Documents, irrespective of whether as a result thereof
the Agent shall acquire title to any collateral, each Lender, upon demand therefor from time to
time, shall contribute its share (based on its Percentage) of the reasonable costs and/or expenses
of any such enforcement or acquisition, including, but not limited to, fees of receivers or
trustees, court costs, title company charges, filing and recording fees, appraisers’ fees and fees
and expenses of attorneys to the extent not otherwise reimbursed by Borrower. Without limiting the
generality of the foregoing, each Lender shall contribute its share (based on its Percentage) of
all reasonable costs and expenses incurred by the Agent (including reasonable attorneys’ fees and
expenses) if the Agent employs counsel for advice or other representation (whether or not any suit
has been or shall be filed) with respect to any collateral for the Loan or any part thereof, or any
of the Loan Documents, or the attempt to enforce any security interest or lien on any collateral,
or to enforce any rights of the Agent or the Lenders or any of Borrower’s or any other party’s
obligations under any of the Loan Documents, but not with respect to any dispute between Agent and
any other Lender(s).

     (d) In the event that all or any portion of the collateral for the Loan is acquired by the
Agent as the result of the exercise of any remedies hereunder or under any other Loan Document, or
is retained in satisfaction of all or any part of Borrower’s obligations under the Loan Documents,
title to any such collateral or any portion thereof shall be held in the name of the Agent or a
nominee or subsidiary of Agent, as agent, for the ratable benefit of the Agent and the Lenders.
The Agent shall prepare a recommended course of action for such collateral (the “Post-Default
Plan”), which shall be subject to the approval of the Required Lenders. The Agent shall administer

56

 

the collateral in accordance with the Post-Default Plan, and upon demand therefor from time to
time, each Lender will contribute its share (based on its Percentage) of all reasonable costs and
expenses incurred by the Agent pursuant to the Post-Default Plan, including without limitation, any
operating losses and all necessary operating reserves. To the extent there is net operating income
from such collateral, the Agent shall, in accordance with the Post-Default Plan, determine the
amount and timing of distributions to Lenders. All such distributions shall be made to Lenders in
accordance with their respective Percentages. In no event shall the provisions of this subsection
or the Post-Default Plan require the Agent or any Lender to take an action which would cause such
Lender to be in violation of any applicable regulatory requirements.

25.8 Lender Actions Against Borrower or the Collateral.

     Each Lender agrees that it will not take any action, nor institute any actions or proceedings,
against Borrower or any other person hereunder or under any other Loan Documents with respect to
exercising claims against the Borrower or rights in any collateral without the consent of the
Required Lenders. With respect to any action by the Agent to enforce the rights and remedies of
the Agent and Lenders with respect to the Borrower and any collateral in accordance with the terms
of this Agreement, each Lender hereby consents to the jurisdiction of the court in which such
action is maintained. In the event a bankruptcy or other insolvency proceeding is commenced by or
against Borrower or any Guarantor with respect to the Obligations, the Agent shall have the sole
and exclusive right to file and pursue a joint proof claim on behalf of all Lenders. Any votes
with respect to such claims or otherwise with respect to such proceedings shall be subject to the
vote of the Required Lenders or all of the Lenders as required by this Agreement. Each Lender
irrevocably waives its right to file or pursue a separate proof of claim in any such proceedings
unless Agent fails to file such claim within thirty (30) days after receipt of written notice from
the Lenders requesting that Agent file such proof of claim.

25.9 Assignment and Participation

     No Lender shall be permitted to assign or sell all or any portion of its rights and
obligations under this Agreement to Borrower or any Affiliate of Borrower.

25.10 Ratable Sharing

     Subject to Sections 25.4 and 25.5, Lenders agree among themselves that (i)
with respect to all amounts received by them which are applicable to the payment of the Loan,
equitable adjustment will be made so that, in effect, all such amounts will be shared among them
ratably in accordance with their Percentages, whether received by voluntary payment, by the
exercise of the right of set-off or bankers’ lien, by counterclaim or cross action or by the
enforcement of any or all of the Loan Documents or any collateral and (ii) if any of them shall by
voluntary payment or by the exercise of any right of counterclaim, set-off, bankers’ lien or
otherwise, receive payment of a proportion of the aggregate amount of the Loan held by it which is
greater than its Percentage of the payments on account of the Loan, the one receiving such excess
payment shall purchase, without recourse or warranty, an undivided interest and participation
(which it shall be deemed to have done simultaneously upon the receipt of such payment) in such
obligations owed to the others so that all such recoveries with respect to such obligations shall
be applied ratably in accordance with their Percentages; provided, that if all or part of such
excess payment received by the purchasing party is thereafter recovered from it, those purchases
shall be rescinded and the purchase prices paid for such participations shall be returned to that
party to the extent necessary to adjust for such recovery, but without interest except to the
extent the purchasing party is required to pay interest in connection with such recovery. Borrower
agrees that any Lender so purchasing a participation from another Lender pursuant to this Section
may, to the fullest extent permitted by law, exercise all its rights of payment (including the
right of set-off) with respect to such participation as fully as if such Lender were the direct
creditor of Borrower in the amount of such participation.

25.11 General Immunity

     Neither Agent nor any of its directors, officers, agents or employees shall be liable to
Borrower or any Lender for any action taken or omitted to be taken by it or them hereunder or under
any other Loan Document or in connection herewith or therewith, except for its or their own gross
negligence or willful misconduct as finally determined by a court of competent jurisdiction after
the expiration of all applicable appeal periods. In the absence of gross negligence, the Agent
shall not be liable for any apportionment or distribution of payments made by it in

57

 

good faith pursuant to Section 25.5, and if any such apportionment or distribution is
subsequently determined to have been made in error the sole recourse of any Lender to whom payment
was due, but not made, shall be to recover from the recipients of such payments any payment in
excess of the amount to which they are determined to have been entitled.

25.12 No Responsibility for Loan, Recitals, etc.

     The Agent shall not be responsible for the execution or validity or enforceability of this
Agreement, the Notes, any of the other Loan Documents or any instrument at any time constituting,
or intended to constitute, collateral security for the Notes, or for the value of any such
collateral security or for the validity, enforceability or collectability of any such amounts owing
with respect to the Notes, or for any recitals or statements, warranties or representations made
herein, or any agreement, instrument or certificate delivered in connection therewith or in any of
the other Loan Documents or in any certificate or instrument hereafter furnished to it by or on
behalf of the Borrower, the Guarantors, or be bound to ascertain or inquire as to the performance
or observance of any of the terms, conditions, covenants or agreements herein or in any of the
other Loan Documents. The Agent shall not be bound to ascertain whether any notice, consent,
waiver or request delivered to it by the Borrower, the Guarantors or any holder of any Note shall
have been duly authorized or is true, accurate and complete. The Agent has not made nor does it
now make any representations or warranties, express or implied, nor does it assume any liability to
the Lenders, with respect to the creditworthiness or financial condition of the Borrower, the
Guarantors, or the value of the Collateral or any other assets of the Borrower or the Guarantors.
Each Lender acknowledges that it has, independently and without reliance upon the Agent or any
other Lender, and based upon such information and documents as it has deemed appropriate, made its
own credit analysis and decision to enter into this Agreement. Each Lender also acknowledges that
it will, independently and without reliance upon the Agent or any other Lender, based upon such
information and documents as it deems appropriate at the time, continue to make its own credit
analysis and decisions in taking or not taking action under this Agreement and the other Loan
Documents. Agent’s Special Counsel has only represented Agent and KeyBank in connection with the
Loan Documents and the only attorney client relationship or duty of care is between Agent’s Special
Counsel and Agent or KeyBank. Each Lender has been independently represented by separate counsel on
all matters regarding the Loan Documents and the granting and perfecting of liens in the
Collateral.

25.13 Action on Instructions of Lenders

     The Agent shall in all cases be fully protected in acting, or in refraining from acting,
hereunder and under any other Loan Document in accordance with written instructions signed by all
the Lenders (or the Required Lenders, if such action may be directed hereunder by the Required
Lenders), and such instructions and any action taken or failure to act pursuant thereto shall be
binding on all of Lenders; provided, however that the Agent need not comply with
any such direction to the extent that the Agent reasonably believes the Agent’s compliance with
such direction to be unlawful in any applicable jurisdiction or commercially unreasonable under the
UCC as enacted in any applicable jurisdiction. Each Lender, severally to the extent of its
Percentage, hereby agrees to indemnify Agent against and hold it harmless from any and all
liability, cost and expense that it may incur by reason of taking or continuing to take any such
action, provided that the foregoing shall not release Agent from liability for its gross negligence
or willful misconduct as finally determined by a court of competent jurisdiction after the
expiration of all applicable appeal periods.

25.14 Employment of Agents and Counsel

     The Agent may undertake any of its duties as Agent hereunder and under any other Loan Document
by or through employees, agents, and attorneys-in-fact and shall not be liable to Lenders, except
as to money or securities received by them or their authorized agents, for the default or
misconduct of any such agents or attorneys-in-fact selected by it with reasonable care. The Agent
shall be entitled to take and rely upon advice of counsel concerning all matters pertaining to the
agency hereby created and its duties hereunder and under any other Loan Document.

25.15 Reliance on Documents; Counsel

     The Agent shall be entitled to rely upon any notice, consent, certificate, affidavit, letter,
telegram, statement, paper or document believed by it to be genuine and correct and to have been
signed or sent by the proper

58

 

person or persons, and, in respect to legal matters, upon the opinion of counsel selected by
the Agent, which counsel may be an employee of Agent, provided that the foregoing shall not release
the Agent from liability for its gross negligence or willful misconduct.

25.16 Agent’s Reimbursement and Indemnification

     Lenders agree to reimburse and indemnify Agent ratably based upon their Percentage (i) for any
amounts (excluding principal and interest on the Loan and loan fees) not reimbursed by Borrower for
which Agent is entitled to reimbursement under the Loan Documents, (ii) for any other expenses
incurred by Agent on behalf of Lenders, in connection with the preparation, execution, delivery,
administration and enforcement of the Loan Documents, if not paid by Borrower, (iii) for any
expenses incurred by Agent on behalf of Lenders which may be necessary or desirable to preserve and
maintain collateral or to perfect and maintain perfected the liens upon the collateral granted
pursuant to this Agreement and the other Loan Documents, if not paid by Borrower, (iv) for any
amounts and other expenses incurred by Agent on behalf of Lenders in connection with any default by
any Lender hereunder or under the other Loan Documents, if not paid by such Lender, and (v) for any
liabilities, obligations, losses, damages, penalties, actions, judgments, suits, costs, expenses or
disbursements of any kind and nature whatsoever which may be imposed on, incurred by or asserted
against Agent in any way relating to or arising out of the Loan Documents or any other document
delivered in connection therewith or the transactions contemplated thereby, or the enforcement of
any of the terms thereof or of any such other documents, provided that no Lender shall be liable
for any of the foregoing to the extent they arise from the gross negligence or willful misconduct
of Agent as finally determined by a court of competent jurisdiction after the expiration of all
applicable appeal periods. The agreements of this Section 25.16 shall survive the
termination of this Agreement and the payment of all amounts payable under the Loan Documents.

25.17 Rights as a Lender

     With respect to its Commitment, if any, Agent shall have the same rights, powers and
obligations hereunder and under any other Loan Document as any Lender and may exercise such rights
and powers as though it were not an Agent, and the term “Lender” or “Lenders” shall, unless the
context otherwise indicates, include Agent in its individual capacities. The Borrower and each
Lender acknowledge and agree that Agent and/or its affiliates may act as trustee under indentures,
serve as financial advisor of, accept deposits from, lend money to, hold other investments in, and
generally engage in any kind of trust, debt, equity or other transaction or have other
relationships, in addition to those contemplated by this Agreement or any other Loan Document, with
Borrower or any of its affiliates in which Borrower or such affiliate is not restricted hereby from
engaging with any other person. The Lenders acknowledge that, pursuant to such activities, Agent,
or its affiliates may receive information regarding such Persons (including, information that may
subject to confidentiality obligations in favor of such Person) and acknowledge that the Agent
shall be under no obligation to provide such information to them.

25.18 Lenders’ Credit Decisions

     Each Lender acknowledges that it has, independently and without reliance upon the Agent or any
other Lender and based on the financial statements and other information prepared by Borrower and
such other documents and information as it has deemed appropriate, made its own credit analysis and
decision to enter into this Agreement and the other Loan Documents. Each Lender also acknowledges
that it will, independently and without reliance upon Agent or any other Lender and based on such
documents and information as it shall deem appropriate at the time, continue to make its own credit
decisions in taking or not taking action under this Agreement and the other Loan Documents.

25.19 Notice of Events of Default

     Should Agent receive any written notice of the occurrence of a default or Event of Default, or
should the Agent send Borrower a notice of Default or Event of Default, the Agent shall promptly
furnish a copy thereof to each Lender. The Agent shall not be deemed to have knowledge or notice
of the occurrence of any Default or Event of Default, except with respect to defaults in the
payment of principal, interest and fees required to be paid to the Agent for the account of the
Lenders, unless the Agent has received notice from a Lender or the Borrower referring

59

 

to the Loan Documents and describing with reasonable specificity such Default or Event of
Default and stating that such notice is a “notice of default”.

25.20 Successor Agent

     (a) Agent may resign from the performance of all its functions and duties hereunder at any
time by giving at least thirty (30) days prior written notice to Lenders and Borrower. Such
resignation shall take effect on the date set forth in such notice or as otherwise provided below.
Such resignation by Agent as agent shall not affect its obligations hereunder, if any, as a Lender.

     (b) Upon resignation by the Agent, or any successor Agent, the Required Lenders shall appoint
a successor Agent with the consent of Borrower, which shall not be unreasonably withheld,
conditioned or delayed (provided that no consent of Borrower shall be required if the successor
Agent is also a Lender or if an Event of Default then exists). If no successor Agent shall have
been so appointed by the Required Lenders, and shall have accepted such appointment within thirty
(30) days after the retiring Agent’s giving notice of resignation, then the retiring Agent may
appoint a successor Agent with the consent of Borrower, which shall not be unreasonably withheld,
conditioned or delayed (provided that no consent of Borrower shall be required if the successor
Agent is also a Lender or if an Event of Default then exists). Upon the acceptance of any
appointment as an Agent hereunder by a successor Agent, such successor Agent shall thereupon
succeed to and become vested with all the rights, powers, privileges and duties of the Agent and
the Agent, and the retiring Agent shall be discharged from its duties and obligations hereunder and
under the other Loan Documents other than its liability, if any, for duties and obligations accrued
prior to its retirement. After any retiring Agent’s resignation hereunder as an Agent, the
provisions of this Article 25 shall continue in effect for its benefit in respect of any
actions taken or omitted to be taken by it while it was acting as an Agent hereunder and under the
other Loan Documents.

25.21 Disclosure

     Borrower agrees to promptly cooperate with any Lender in connection with any proposed
assignment or participation of all or any portion of its Commitment. The Borrower agrees that in
addition to disclosures made in accordance with standard banking practices any Lender may disclose
information obtained by such Lender pursuant to this Agreement to assignees or participants and
potential assignees or participants hereunder. Each Lender agrees for itself that it shall use
reasonable efforts in accordance with its customary procedures to hold confidential all non-public
information obtained from Parent Guarantor, OP Guarantor or Borrower that has been identified
verbally or in writing as confidential by any of them, and shall use reasonable efforts in
accordance with its customary procedures to not disclose such information to any other Person, it
being understood and agreed that, notwithstanding the foregoing, a Lender may make (a) disclosures
to its participants (provided such Persons are advised of the provisions of this Section
25.21), (b) disclosures to its directors, officers, employees, Affiliates, accountants,
appraisers, legal counsel and other professional advisors of such Lender (provided that such
Persons who are not employees of such Lender are advised of the provision of this Section
25.21), (c) disclosures customarily provided or reasonably required by any potential or actual
bona fide assignee, transferee or participant or their respective directors, officers, employees,
Affiliates, accountants, appraisers, legal counsel and other professional advisors in connection
with a potential or actual assignment or transfer by such Lender of any Loans or any participations
therein (provided such Persons are advised of the provisions of this Section 25.21), (d)
disclosures to bank regulatory authorities or self-regulatory bodies with jurisdiction over such
Lender, or (e) disclosures required or requested by any other governmental authority or
representative thereof or pursuant to legal process; provided that, unless specifically prohibited
by applicable law or court order, each Lender shall notify Borrower of any request by any
governmental authority or representative thereof prior to disclosure (other than any such request
in connection with any examination of such Lender by such government authority) for disclosure of
any such non-public information prior to disclosure of such information. In addition, each Lender
may make disclosure of such information to any contractual counterparty in swap agreements or such
contractual counterparty’s professional advisors (so long as such contractual counterparty or
professional advisors agree to be bound by the provisions of this Section 25.21).
Non-public information shall not include any information which is or subsequently becomes publicly
available other than as a result of a disclosure of such information by a Lender, or prior to the
delivery to such Lender is within the possession of such Lender if such information is not known by
such Lender to be subject to another confidentiality agreement with or other obligations of secrecy
to Parent Guarantor, OP Guarantor or the

60

 

Borrower, or is disclosed with the prior approval of Borrower. Nothing herein shall prohibit
the disclosure of non-public information to the extent necessary to enforce the Loan Documents.

[CONTINUED ON NEXT PAGE]

61

 

     EXECUTED as of the date first set forth above.

	 	 	 	 	 	 	 
	BORROWER:	 	REPUBLIC 20TH STREET LLC, a Delaware limited

liability company	 	 
	 
	 	 	 	 	 	 
	 

	 	By:
	 	/s/ Gary R. Siegel
	 	 
	 

	 	 	 	 	 	 
	 	 	Name: Gary R. Siegel	 	 
	 	 	Title: Chief Operating Officer	 	 
	 
	 	 	 	 	 	 
	 	 	Borrower’s Tax ID No.: 20-3241959	 	 

62

 

	 	 	 	 	 	 	 
	AGENT AND LENDER:	 	 KEYBANK NATIONAL ASSOCIATION, individually and as Agent	 	 
	 
	 	 	 	 	 	 
	 

	 	By:
	 	/s/ Michael P. Szuba
	 	 
	 

	 	 	 	 	 	 
	 	 	Name: Michael P. Szuba	 	 
	 	 	Title: Vice-President	 	 
	 
	 	 	 	 	 	 
	 	 	Commitment: $74,000,000.00	 	 

63

 

EXHIBIT A

Legal Description of Land

All that certain property located in the City of Washington, District of Columbia, known as Lot
numbered 75 in Square numbered 117 in a subdivision made by Ralph L. Feltman and Ruth S. Feltman as
per plat recorded in Liber 154 at folio 17 in the Office of the Surveyor for the District of
Columbia and described as now surveyed:

Beginning for the same at an x-cut in concrete located at the westerly corner common to Lots 75 and
84, Square 117, said point located also on the easterly line of 20th Street, N.W. (90 feet wide,
nominal) and running thence with and along the easterly line of 20th Street, N.W.

	(1)	 	North, 144.75 feet (record), North, 144.94 feet (measured) to an x-cut in concrete at the
northwest corner of Lot 75, and running thence with and along the south line of a public alley
(15 feet wide)
	 
	(2)	 	East, 135.83 feet (record & measured) to a nail set; thence
	 
	(3)	 	South 45° 00’ 00” East, 7.07 feet (record & measured) to a nail set on the west line of a
public alley (10 feet wide); thence
	 
	(4)	 	South, 139.75 feet (record), South, 139.94 feet (measured) to an x-cut in concrete at the
easterly corner common to Lot 75 and Lot 84, Square 117 and running thence with and along the
line between said lots
	 
	(5)	 	West, 140.83 feet (record & measured) to the point of beginning, containing 20,372.64 square
feet (record), 20,399 square feet (measured) of land.

Together with rights arising under that certain Certificate of Transfer of Development Rights
(Number Seven) dated as of April 13, 2006 by and among Massachusetts Court Apartments, L.L.C., a
Delaware limited liability company, 1129 29th Street NY Owner LLC, a Delaware limited liability
company, and the District of Columbia, a municipal corporation, recorded on July 24, 2006 as
Instrument Number 2006099748.

A-1

 

 

EXHIBIT B

Permitted Exceptions

Permitted encumbrances are such matters as are shown on Schedule B, Part I to the Pro-Forma Title
Insurance Policy No. 07-001041 issued by Commonwealth Land Title Insurance Company to the Agent in
connection with this Instrument and attached to that certain escrow instruction letter dated on or
about the date hereof between LandAmerica Commercial Services and Agent.

B-1

 

 

EXHIBIT C

Form of Note

NOTE

			
	 	 	 
	$                    
	 	February ___, 2007

     FOR VALUE RECEIVED, the undersigned, REPUBLIC 20TH STREET LLC, a Delaware limited
liability company (“Maker”), hereby promises to pay to
___  ___ (“Payee”), or order, in accordance with the terms of that certain Construction Loan Agreement,
dated as of February 16, 2007, as from time to time in effect, among Maker, KeyBank National
Association, for itself and as Agent, and such other Lenders as may be from time to time named
therein (the “Loan Agreement”), to the extent not sooner paid, on or before the Maturity Date, the
principal sum of ___($___), or such amount as may be advanced by the Payee
under the Loan Agreement as a Loan with daily interest from the date thereof, computed as provided
in the Loan Agreement, on the principal amount hereof from time to time unpaid, at a rate per annum
on each portion of the principal amount which shall at all times be equal to the rate of interest
applicable to such portion in accordance with the Loan Agreement, and with interest on overdue
principal and, to the extent permitted by applicable law, on overdue installments of interest and
late charges at the rates provided in the Loan Agreement. Interest shall be payable on the dates
specified in the Loan Agreement, except that all accrued interest shall be paid at the stated or
accelerated maturity hereof or upon the prepayment in full hereof. Capitalized terms used herein
and not otherwise defined herein shall have the meanings set forth in the Loan Agreement.

     Payments hereunder shall be made to the Agent for the Payee at 127 Public Square, Cleveland,
Ohio 44114-1306, or at such other address as Agent may designate from time to time.

     This Note is one of one or more Notes evidencing borrowings under and is entitled to the
benefits and subject to the provisions of the Loan Agreement. The principal of this Note may be
due and payable in whole or in part prior to the Maturity Date and is subject to mandatory
prepayment in the amounts and under the circumstances set forth in the Loan Agreement, and may be
prepaid in whole or from time to time in part, all as set forth in the Loan Agreement.

     Notwithstanding anything in this Note to the contrary, all agreements between the undersigned
Maker and the Lenders and the Agent, whether now existing or hereafter arising and whether written
or oral, are hereby limited so that in no contingency, whether by reason of acceleration of the
maturity of any of the Obligations or otherwise, shall the interest contracted for, charged or
received by the Lenders exceed the maximum amount permissible under applicable law. If, from any
circumstance whatsoever, interest would otherwise be payable to the Lenders in excess of the
maximum lawful amount, the interest payable to the Lenders shall be reduced to the maximum amount
permitted under applicable law; and if from any circumstance the Lenders shall ever receive
anything of value deemed interest by applicable law in excess of the maximum lawful amount, an
amount equal to any excessive interest shall be applied to the reduction of the principal balance
of the Obligations of the undersigned Maker and to the payment of interest or, if such excessive
interest exceeds the unpaid balance of principal of the Obligations of the undersigned Maker, such
excess shall be refunded to the undersigned Maker. All interest paid or agreed to be paid to the
Lenders shall, to the extent permitted by applicable law, be amortized, prorated, allocated and
spread throughout the full period until payment in full of the principal of the Obligations of the
undersigned Maker (including the period of any renewal or extension thereof) so that the interest
thereon for such full period shall not exceed the maximum amount permitted by applicable law.
Maker agrees to pay an effective rate of interest that is the sum of the applicable rate provided
in the Loan Agreement plus any additional rate of interest resulting from any charges of interest
or in the nature of interest paid or to be paid in connections with the loan evidenced by this
Note. This paragraph shall control all agreements between the undersigned Maker and the Lenders
and the Agent.

     In case an Event of Default shall occur, the entire principal amount of this Note may become
or be declared due and payable in the manner and with the effect provided in said Loan Agreement.

     This Note shall be governed by the laws of the District of Columbia.

C-1

 

 

     The undersigned Maker and all guarantors and endorsers hereby waive presentment, demand,
notice, protest, notice of intention to accelerate the indebtedness evidenced hereby, notice of
acceleration of the indebtedness evidenced hereby and all other demands and notices in connection
with the delivery, acceptance, performance and enforcement of this Note, except as specifically
otherwise provided in the Loan Agreement, and assent to extensions of time of payment or
forbearance or other indulgence without notice.

     IN WITNESS WHEREOF, the undersigned has by its duly authorized officer executed this Note
under seal on the day and year first above written.

	 	 	 	 	 	 	 
	 	 	REPUBLIC 20TH STREET LLC, a Delaware

limited liability company	 	 
	 
	 	 	 	 	 	 
	 

	 	By:
	 	 	 	 
	 

	 	 	 	 	 	 
	 

	 	Name:	 	 	 	 
	 

	 	 	 	 	 	 
	 

	 	Title:	 	 	 	 
	 

	 	 	 	 	 	 
	 
	 	 	 	 	 	 
	 

	 	 	 	[SEAL]	 	 

C-2

 

 

EXHIBIT D

Intentionally Omitted

D-1

 

 

EXHIBIT E

LIBOR NOTICE ELECTION

NOTICE OF LIBOR FUNDING ELECTION

KeyBank National Association, as Agent

127 Public Square, 8th Floor

OH 01-27-0844

Cleveland, Ohio 44114

Attention: Michael P. Szuba

Date:

Ladies and Gentlemen:

     Reference is made to the promissory notes made by Republic 20th Street LLC
(“Borrower”), in favor or KeyBank National Association and the other Lenders (the “Notes”) pursuant
to that certain Construction Loan Agreement dated as of February 16, 2007, by and between Borrower,
KeyBank National Association, as a lender and as Administrative Agent and the lenders named
therein. The undersigned hereby gives notice pursuant to Section 5.1 of the Loan Agreement of its
desire for a LIBOR FUNDING ELECTION of a portion of the proceeds of the loan evidenced by the
Notes.

     The Following are the details of the LIBOR funding election to be set up as of the
commencement date specified below:

     1. The LIBOR funding commencement date is:

     2. The LIBOR funding period expires:

     3. The LIBOR funding principal amount is:

     4. The LIBOR funding rate is LIBOR plus ___%, or

     The sources for the above LIBOR are as follows (Choose as appropriate):

Prime Note Outstanding Balance:

Draw #____ Advance:

Interest due:

Current LIBOR maturing _____:

Current LIBOR maturing _____:

Total:

     The next LIBOR FUNDING ELECTION NOTIFICATION date is ___.

E-1

 

 

EXHIBIT F

Insurance Requirements

     Borrower shall obtain and keep in full force and effect either builder’s risk insurance (the
“Builder’s Risk Insurance policy”) coverage or permanent All Perils insurance coverage as
appropriate, satisfactory to Agent, on the Project. All insurance policies shall be issued by
carriers with a Best’s Insurance Reports policy holder’s rating of A and a financial size category
of Class X and shall include a standard mortgage clause (without contribution) in favor of and
acceptable to Agent. The policies shall provide for the following, and any other coverage that
Agent may from time to time deem necessary:

	 	a)	 	Coverage Against All Peril and/or Builders Risk in the amount of 100% of the
replacement cost of all Improvements located or to be located on the Land. If the
policy is written on a CO-INSURANCE basis, the policy shall contain an AGREED AMOUNT
ENDORSEMENT as evidence that the coverage is in an amount sufficient to insure the full
amount of the mortgage indebtedness. “KeyBank National Association, as Agent, and its
successors and assigns” shall be named as the “Mortgagee” and “Loss Payee”.
	 
	 	b)	 	Public liability coverage in a minimum amount of not less than $2,000,000 per
occurrence and $5,000,000 in the aggregate. “KeyBank National Association, as Agent,
the Lenders and their successors and assigns” shall be named as an “Additional
Insured”.
	 
	 	c)	 	Rent loss or business interruption coverage in a minimum amount approved by
Agent of not less than the appraised rentals for a minimum of twelve months.
	 
	 	d)	 	Flood hazard coverage in a minimum amount available, if the premises are
located in a special flood hazard area (“Flood Hazard Area”) as designated by the
Federal Emergency Management Agency on its Flood Hazard Boundary Map and Flood
Insurance Rate Maps, and the Department of Housing and Urban Development, Federal
Insurance Administration, Special Flood Hazard Area Maps.
	 
	 	e)	 	Workers Compensation and Disability insurance as required by law.
	 
	 	f)	 	Such other types and amounts of insurance with respect to the premises and the
operation thereof which are commonly maintained in the case of other property and
buildings similar to the premises in nature, use, location, height, and type of
construction, as may from time to time be required by the mortgagee.

Each policy shall provide that it may not be canceled, reduced or terminated without at least
thirty (30) days prior written notice to Agent.

F-1

 

 

EXHIBIT G

Architect’s Certificate

     The firm of                      hereby certifies for the benefit of
KeyBank National Association that:

     The firm has been employed by                                          pursuant to a contract
dated                      to provide architectural and engineering services commonly known
as                                          which is located at
                                        .

     The contract provides for the following services:

Preparation of plans and specifications

Pre-qualification of contractors

Contract administration and supervision of construction

Tenant space design

     The firm is duly licensed and in good standing under laws of the state of ___
License No. ___.

     The foundations and existing improvements are sufficient to support the improvements described
in the plans listed on the attached Schedule 1.

     The following are all of the permits or governmental agency approvals required for the
construction and occupancy of the building:

	 	 	 	 	 
	 	 	Issuing Agency	 	Date Issued
	Excavation Permit
	 	 	 	 
	 
	 	 	 	 
	Foundation Permit
	 	 	 	 
	 
	 	 	 	 
	Building Permit
	 	 	 	 
	 
	 	 	 	 
	EPA – Water
	 	 	 	 
	 
	 	 	 	 
	EPA – Sewer
	 	 	 	 
	 
	 	 	 	 
	EPA – Air
	 	 	 	 
	 
	 	 	 	 
	Cert. Of Occupancy Bldg.
	 	 	 	 
	 
	 	 	 	 
	Cert. Of Occupancy – Tenant
	 	 	 	 
	 
	 	 	 	 
	Other (Specify)
	 	 	 	 

     All utilities necessary for the operation of the project are available with sufficient
capacity at the boundaries of the project.

     The plans listed on the attached Schedule I comprise all of the plans which will be necessary
for the complete construction of the project, excepting tenant space designs, and when the project
is built in accordance therewith the project will (excepting completion of tenant improvements) be
ready for occupancy. The plans are complete and contain all detail necessary for construction.
Calculations of the gross building and the net rentable building area are attached as Schedule II.
The plans (and the project will, when constructed in accordance

G-1

 

 

therewith) comply with all applicable building, zoning, land use, subdivision, environmental,
fire, safety and other applicable governmental laws, statutes, codes, ordinances, rules and
regulations. The project is in compliance with all requirements of the Americans with Disabilities
Act of 1990 which requires that places of public accommodation be made readily accessible to
disabled individuals.

     The attached Schedule III, establishing a timetable for completion of the project and showing
on a monthly basis the anticipated progress of the work, is realistic and can be adhered to.

     The following design drawings or plans have been or will be prepared by other designers or
contractors.

	 	 	 
	Type of Plans

	 	Name of Preparing Firm

The Specifications are:                                         shown on plans

                                                                      Bound separately

	 	 	 	 	 	 	 
	 

	 	By:
	 	 	 	 
	 

	 	 	 	 	 	 
	 

	 	Title:	 	 	 	 
	 

	 	 	 	 	 	 
	 

	 	Date:	 	 	 	 
	 

	 	 	 	 	 	 

G-2

 

 

EXHIBIT H

Initial Budget

H-1

 

 

EXHIBIT I

Borrower’s Certificate

KeyBank National Association, as Agent

127 Public Square, 8th Floor

OH 01-27-0844

Cleveland, Ohio 44114

Attention: Michael P. Szuba

	 	 	RE: Application for Advance or confirmation of equity
contribution in connection with a $___loan
(#___) to Republic 20th
Street LLC (“Borrower”).

	 	1.	 	Pursuant to that certain Construction Loan Agreement dated February 16, 2007
(the “Construction Loan Agreement”) between Borrower, KeyBank National Association
(“Agent”) individually and as Administrative Agent, and the other lenders therein,
Borrower

	 	(a)	 	hereby requests a loan advance as indicated on the Soft and
Hard Cost Requisition attached hereto. We acknowledge that this amount is
subject to inspection, verification, and available funds.
	 
	 	(b)	 	acknowledges and confirms an equity contribution as indicated
on the Soft and Hard Cost Requisition attached hereto.

Funding Instructions

	 	2.	 	This Borrower’s Certificate is to be utilized only in satisfaction of costs and
charges with respect to the Project and Improvements thereon as shown on the Soft and
Hard Cost Requisition Form, dated ___, attached hereto.
	 
	 	3.	 	The Borrower agrees to provide, if requested by Agent, a vendor payee listing
showing the name and the amount currently due each party to whom Borrower is obligated
for labor, material and/or services supplies. This information would be provided in
support of the disbursements set forth in paragraph 1(a) hereof.
	 
	 	4.	 	The Borrower also certifies and agrees that:

	 	(a)	 	It has complied with all duties and obligations required to
date to be carried out and performed by it pursuant to the terms of the
Construction Loan Agreement;
	 
	 	(b)	 	No Event of Default as defined in the Construction Loan
Agreement has occurred and is continuing nor any event, circumstance or
condition which with notice or the passage of time or both would be an Event of
Default, and;
	 
	 	(c)	 	All Change Orders or changes to the Budget have been submitted
to and approved by Agent to the extent required under the Construction Loan
Agreement;
	 
	 	(d)	 	All funds previously disbursed have been used for the purposes
as set forth in the Construction Loan Agreement;
	 
	 	(e)	 	All outstanding claims for labor, materials and/or services
furnished prior to this draw period have been paid or will be paid from the
proceeds of this disbursement;
	 
	 	(f)	 	All construction prior to the date of this Borrower’s
Certificate has been accomplished in accordance with the Plans and
Specifications approved by Agent;

I-1

 

 

	 	(g)	 	All sums advanced by Lenders will be used solely for the
purpose of paying costs of the project owing as shown on the attached Soft and
Hard Cost Requisition and no disbursement requested hereunder has been the
basis for any prior disbursement of the Loan;
	 
	 	(h)	 	There are no liens outstanding against the subject project or
its equipment except for Agent’s liens and security interests as agreed upon in
the Construction Loan Agreement;
	 
	 	(i)	 	The amount of undisbursed Loan proceeds and/or approved equity
requirement remaining is sufficient to pay the cost of completing the Project
in accordance with the Plans and Specifications and Budget approved by Lenders
as modified by Agent approved Change Orders;
	 
	 	(j)	 	All representations and warranties contained in the
Construction Loan Agreement are true and correct as of the date hereof.
	 
	 	(k)	 	The undersigned understands that this certification is made for
the purpose of inducing Lenders to make a disbursement to Borrower and that, in
making such disbursement, Lenders will rely upon the accuracy of the matters
stated in this Certificate.

	 	5.	 	Disbursement of the loan proceeds hereby requested are subject to the receipt
by Agent, in those states where applicable, of a certificate from the issuing title
company stating that no claims have been filed of record which adversely affects the
title of Borrower to the Project, subsequent to the filing of the Deed of Trust.
	 
	 	6.	 	The terms used in this Borrower’s Certificate have the same meaning and
definitions as those set forth in the Construction Loan Agreement.
	 
	 	7.	 	The Borrower, or authorized signer, certifies that the statements made in this
Borrower’s Certificate and any documents submitted herewith and identified herein are
true and has duly caused this Borrower’s Certificate to be signed on its behalf by the
Authorized Representative.

	 	 	 	 	 	 	 
	 

	 	DATE:
	 	 	 	 
	 

	 	 	 	 	 	 
	 
	 	 	 	 	 	 
	 

	 	BORROWER:	 	 	 	 
	 

	 	 	 	 	 	 
	 
	 	 	 	 	 	 
	 

	 	BY:	 	 	 	 
	 

	 	 	 	 	 	 
	 
	 	 	 	 	 	 
	 

	 	ITS:	 	 	 	 
	 

	 	 	 	 	 	 

I-2

 

 

EXHIBIT J

Soft and Hard Cost Requisition Form

J-1

 

 

EXHIBIT K

Certificate of Compliance

KeyBank National Association, as Agent

127 Public Square, 8th Floor

OH 01-27-0844

Cleveland, Ohio 44114

Attention: Michael P. Szuba

			
	Re:	 	Construction Loan Agreement dated as of February 16,
2007 (as amended, modified, supplemented, restated, or
renewed, from time to time, the “Agreement”), between
REPUBLIC 20TH STREET LLC (the “Borrower”),
and KEYBANK NATIONAL ASSOCIATION, for itself and as
administrative agent on behalf of the Lenders included
therein (“Agent”).

Reference is made to the Agreement. Capitalized terms used in this Certificate (including
schedules and other attachments hereto, this “Certificate”) without definition have the meanings
specified in the Agreement.

Pursuant to applicable provisions of the Agreement, the undersigned, being the Authorized
Representative designated in the Agreement, hereby certifies to the Agent that the information
furnished in the attached schedules, including, without limitation, each of the calculations listed
below are true, correct and complete in all material respects as of the last day of the fiscal
periods subject to the financial statements and associated covenants being delivered to the Agent
pursuant to the Agreement together with this Certificate (such statements the “Financial
Statements” and the periods covered thereby the “reporting period”) and for such reporting periods.

The undersigned hereby further certifies to the Agent that:

1. Debt Service Coverage. As shown below, the Borrower has achieved the Debt Service
Coverage set forth below.

A. Debt Service Coverage of not less than 1.25:1.0

     Calculation:

     Debt Service Coverage = Net Operating Income/Total Annual Debt Service Calculation : 1.0.

     Net Operating Income =

     Total Annual Debt Service Calculation =

     Debt Service Coverage of ___: 1.0 for period ending ___.

     [Borrower to include specific calculation based upon formula outlined in Agreement]

IN WITNESS WHEREOF, this Certificate is executed by the undersigned this ___day of ___.

	 	 	 	 	 
	 	REPUBLIC 20TH STREET LLC, a Delaware

limited liability company

 	 
	 	By:  	 	 
	 	 	Authorized Representative 	 
	 	 	 	 
	 

K-1

 

 

EXHIBIT L

ASSIGNMENT AND ASSUMPTION AGREEMENT

DATE: ___, ___, 2___

     This ASSIGNMENT AND ASSUMPTION AGREEMENT (this “Agreement”) is dated as of this ___day of
___, ___, and is made by and between ___(“Assignor”) and ___(“Assignee”).

PRELIMINARY STATEMENT

     Assignor is a party to that certain Construction Loan Agreement dated as of February 16, 2007
(the Construction Loan Agreement, as the same may be amended, supplemented, restated or otherwise
modified from time to time shall be referred to herein as the “Loan Agreement”), by and between
Republic 20TH Street LLC (“Borrower”), and KeyBank National Association, as a lender and
as Administrative Agent and the lenders named therein (collectively, “Lender”). Pursuant to the
Loan Agreement, Lender agreed to make a loan of up to Seventy-Four Million and No/100 Dollars
($74,000,000.00) (the “Loan”) to Borrower to finance Project described in the Loan Agreement.
Assignee desires to purchase from Assignor an undivided interest in the Loan under the terms and
conditions set forth herein. Capitalized terms used herein and not otherwise defined herein shall
have the meanings ascribed to such terms in the Loan Agreement.

AGREEMENT

     Assignor and Assignee, in consideration of the matters described in the foregoing Preliminary
Statement, which are incorporated herein, and in consideration of the mutual covenants and
agreements and provisions herein contained, and for other good and valuable consideration, the
receipt and sufficiency of which are hereby acknowledged, do hereby covenant and agree as follows:

     1. Assignment and Assumption. Assignor hereby sells and assigns to the Assignee, and
the Assignee hereby purchases and assumes from the Assignor, an undivided interest in and to the
Loan and the Loan Documents and Assignor’s rights and obligations thereunder, which interest shall
equal a percentage of ___% and a corresponding Commitment in the maximum amount of
$___, such that after giving effect to this assignment (i) the Assignee shall hold a
Percentage of the Loan equal to ___% and a Commitment in the maximum amount of $___,
together with the outstanding rights and obligations under the Loan Agreement and the other Loan
Documents in connection with such Commitment, and (ii) Assignor shall hold a Percentage of the Loan
equal to ___% and a Commitment in the maximum amount of $___.

     2. Effective Date. The effective date of this Agreement (the “Effective Date”) shall
be ___, ___, which shall be no earlier than three (3) Business Days prior to receipt by
the Agent of a fully executed copy of this Agreement. As of the Effective Date, (i) the Assignee
shall have the rights and obligations of a Bank under the Loan Documents with respect to the rights
and obligations assigned to the Assignee hereunder, the assumption of such obligations by Assignee
inuring to the direct benefit of Borrower, and (ii) the Assignor shall relinquish its rights and be
released from its corresponding obligations under the Loan Documents with respect to the rights and
obligations assigned to the Assignee hereunder.

     3. Payment Obligations. On the Effective Date the Assignee shall pay to Assignor the
outstanding principal balance in respect of the interest purchased hereunder. Accrued and unpaid
interest shall be prorated when received from the Borrower. The Assignee shall advance funds
directly to the Agent with respect to all advances and reimbursement payments to be made on or
after the Effective Date with respect to the interest assigned hereby. Assignee shall not be
entitled to any interest or fees, of any nature, paid by the Borrower to Assignor pursuant to the
Loan Agreement and the other Loan Documents or otherwise owed to Assignor prior to the Effective
Date.

     4. Representations of the Assignor; Limitations on the Assignor’s Liability. The
Assignor represents and warrants that (a) it is the legal and beneficial owner of the interest
being assigned by it hereunder and (b) that such interest is free and clear of any adverse pledge,
security interest, claim or other lien or encumbrance. It is

L-1

 

understood and agreed that the assignment and assumption hereunder are made without recourse
to the Assignor and that the Assignor and Agent make no other representation or warranty of any
kind to the Assignee. Neither the Assignor, Agent, nor any of their officers, directors,
employees, agents or attorneys shall be responsible for (i) the due execution, legality, validity,
enforceability, genuineness, sufficiency or collectability of any Loan Document, including without
limitation, documents granting the Assignor and the other Lenders a security interest in assets of
the Borrower or any Guarantor, (ii) any representation, warranty or statement made in or in
connection with any of the Loan Documents, (iii) the financial condition or creditworthiness of the
Borrower and the Guarantors, (iv) the performance of or compliance with any of the terms or
provisions of any of the Loan Documents, (v) inspecting any of the property, books or records of
the Borrower, (vi) the validity, enforceability, perfection, priority, condition, value or
sufficiency of any collateral securing or purporting to secure the Loan, or (vii) any mistake,
error of judgment, or action taken or omitted to be taken in connection with the Loan or the Loan
Documents. This Section shall survive the assignment of the interest assigned herein.

     5. Representations and Covenants of the Assignee. The Assignee (i) confirms that it
has received a copy of the Loan Agreement, together with copies of such financial statements, Loan
Documents and other documents and information as it has deemed appropriate to make its own credit
analysis and decision to enter into this Agreement, (ii) agrees that it will, independently and
without reliance upon Agent, the Assignor or any other Lender, and based on such documents and
information as it shall deem appropriate at the time, continue to make its own credit decisions in
taking or not taking action under the Loan Documents, (iii) appoints and authorizes the Agent to
take such action on its behalf and to exercise such powers under the Loan Documents as are
delegated to the Administrative Agent by the terms thereof, together with such powers as are
reasonably incidental thereto, (iv) agrees for the benefit of Borrower and the other Lenders that
it will perform in accordance with their terms all of the obligations which by the terms of the
Loan Documents are required to be performed by it as a Lender, (v) agrees that its payment
instructions and notice instructions are as set forth in Schedule 1, (vi) confirms that none of the
funds, monies, assets or other consideration being used to make the purchase and assumption
hereunder are “plan assets” as defined under ERISA and that its rights, benefits and interests in
and under the Loan Documents will not be “plan assets” under ERISA, and (vii) attaches the forms
prescribed by the Internal Revenue Service of the United States certifying that the Assignee is
entitled to receive payments under the Loan Documents without deduction or withholding of any
United States federal income taxes.

     6. Subsequent Assignments. After the Effective Date, the Assignee shall have the
right pursuant to Article 24 of the Loan Agreement to assign the rights which are assigned to the
Assignee, provided that any such subsequent assignment does not violate any of the terms and
conditions of the Loan Documents or any law, rule, regulation, order, writ, judgment, injunction or
decree and that any consent required under the terms of the Loan Documents has been obtained.

     7. Entire Agreement. This Agreement embodies the entire agreement and understanding
between the parties hereto and supersedes all prior agreements and understandings between the
parties hereto relating to the subject matter hereof.

     8. Governing Law. This Agreement shall be governed by the internal law, and not the
law of conflicts, of the District of Columbia.

     9. Notices. Notices shall be given under this Agreement in the manner set forth in
the Loan Agreement.

[remainder of page intentionally left blank]

L-2

 

     IN WITNESS WHEREOF, the parties hereto have executed this Agreement by their duly authorized
officers as of the date first above written.

	 	 	 	 	 	 	 
	ASSIGNOR:

	 	 	 	 	 	 
	 	 	 	 	 
	 
	 	 	 	 	 	 
	 

	 	By:	 	 	 	 
	 

	 	 	 	 	 	 
	 

	 	Name:	 	 	 	 
	 

	 	 	 	 	 	 
	 

	 	Title:	 	 	 	 
	 

	 	 	 	 	 	 
	 
	 	 	 	 	 	 
	ASSIGNEE:
	 	 	 	 	 	 
	 	 	 	 	 
	 
	 	 	 	 	 	 
	 

	 	By:	 	 	 	 
	 

	 	 	 	 	 	 
	 

	 	Name:	 	 	 	 
	 

	 	 	 	 	 	 
	 

	 	Title:	 	 	 	 
	 

	 	 	 	 	 	 
	 
	 	 	 	 	 	 
	CONSENTED TO:	 	 KEYBANK NATIONAL ASSOCIATION,

as Agent	 	 
	 
	 	 	 	 	 	 
	 

	 	By:	 	 	 	 
	 

	 	 	 	 	 	 
	 

	 	Name:	 	 	 	 
	 

	 	 	 	 	 	 
	 

	 	Title:	 	 	 	 
	 

	 	 	 	 	 	 
	 
	 	 	 	 	 	 
	[ADD BORROWER CONSENT IF REQUIRED]
	 	 
	 
	 	 	 	 	 	 
	CONSENTED TO:	 	 REPUBLIC
20TH
STREET LLC, a Delaware limited
liability company	 	 
	 
	 	 	 	 	 	 
	 

	 	By:	 	 	 	 
	 

	 	 	 	 	 	 
	 

	 	Name:	 	 	 	 
	 

	 	 	 	 	 	 
	 

	 	Title:	 	 	 	 
	 

	 	 	 	 	 	 

L-3

 

EXHIBIT M

Patriot Act and OFAC Transferee and Assignee Identifying Information Form

1. Patriot Act Checklist

	 	 	 
	ADDITIONAL LENDER REQUIRED INFORMATION
	 	 
	 
	 	 
	Name:
	 	 
	 
	 	 
	Identification

	 	 
	 
	 	 
	     (a) (US Company) TIN
	(a)                     	 
	           (b) (Non-US) Gov’t issued document certifying existence

	(b)                     	 
	 
	 	 
	Phone Number
	 	 
	 
	 	 
	BUSINESS REPRESENTATIVE REQUIRED INFORMATION
 PERSON WHO
WILL EXECUTE DOCUMENTS
	 	 
	 
	 	 
	Name
	 	 
	 
	 	 
	Residential Address
	 	 
	 
	 	 
	Date of Birth
	 	 
	 
	 	 
	Form of Identification
	 	 
	 
	 	 
	      (a) (US Citizen) Social Security Number

	 	(a)                     
	           (b) (Non-US) TIN, Passport Number (country of
issuance, number & date), or Alien
Identification Number

	 	(b)                     
	 
	 	 
	2. OFAC Checklist:
	 	 
	 
	 	 
	Name:
	 	 
	 
	 	 
	Co-Lenders
	 	 
	 
	 	 
	General Partner/Managing Member/Trustee
	 	 
	 
	 	 
	Limited Partners/Members/Beneficiariesexv10w63

 

	 	 	 
	 
	 	Exhibit 10.63
	 
	PREPARED BY AND

	 	 
	AFTER RECORDING RETURN TO:
	 	 
	William F. Timmons, Esq.

McKenna Long & Aldridge LLP

303 Peachtree Street, N.E., Suite 5300

Atlanta, Georgia 30308
	 	 

$61,750,000.00 OF THE $74,000,000.00 TOTAL INDEBTEDNESS WILL BE ADVANCED BY THE LENDER AT THE TIME
OF RECORDATION AND SHALL BE DEEMED TO BE PURCHASE MONEY (“PURCHASE MONEY”) FOR THE PURPOSE OF
CALCULATING RECORDATION TAXES PAYABLE IN THE DISTRICT OF COLUMBIA. THIS INSTRUMENT SECURES THE
PURCHASE MONEY ADVANCE, FUTURE ADVANCES AND A READVANCE OF SOME OR ALL OF THE ORIGINAL PURCHASE
MONEY ADVANCE.

DEED OF TRUST, ASSIGNMENT OF LEASES AND RENTS,

SECURITY AGREEMENT AND FIXTURE FILING

REPUBLIC 20TH STREET LLC,

a Delaware limited liability company,

GRANTOR

TO

LAWYERS TITLE REALTY SERVICES, INC.,

a Virginia corporation

AS TRUSTEE

FOR THE BENEFIT OF

KEYBANK NATIONAL ASSOCIATION,

a national banking association, as Agent

AGENT

DATED: AS OF FEBRUARY 16, 2007

5

 

          THIS DEED OF TRUST, ASSIGNMENT OF LEASES AND RENTS, SECURITY AGREEMENT AND FIXTURE FILING
(this “Instrument”) is made and entered into as of this 16th day of February, 2007, by and
between REPUBLIC 20TH STREET LLC, a Delaware limited liability company, having a mailing
address of 13861 Sunrise Valley Drive, Suite 410, Herndon, Virginia 20171 (“Grantor”), and
LAWYERS TITLE REALTY SERVICES, INC., a Virginia corporation, as Trustee (“Trustee”), having
a principal place of business at 5600 Cox Road, Glen Allen, Virginia 23060 VA, and having a mailing
address of c/o LandAmerica Commercial Services, 1015 15th Street, N.W., Suite 300, Washington, DC
20005, and KEYBANK NATIONAL ASSOCIATION, a national banking association (“KeyBank”), having
a mailing address of 127 Public Square, Cleveland, Ohio 44114-1306, Attn: Real Estate Capital
Services, as Agent for itself and each other lender (collectively, the “Lenders”) which is
or may hereafter become a party to that certain Construction Loan Agreement, dated of even date
herewith, by and among Grantor, KeyBank, as Agent and the Lenders (as the same may be further
varied, amended, restated, renewed, consolidated, extended or otherwise supplemented from time to
time, the “Loan Agreement”) (KeyBank, in its capacity as Agent, is hereinafter referred to
as “Agent”). Capitalized terms used herein that are not otherwise defined herein shall
have the meanings set forth in the Loan Agreement.

W I T N E S S E T H:

          FOR AND IN CONSIDERATION of the sum of Ten and No/100 Dollars ($10.00) and other valuable
consideration, the receipt and sufficiency of which are hereby acknowledged, and in order to secure
the indebtedness and other obligations of Grantor hereinafter set forth, Grantor does hereby grant,
bargain, sell, convey, assign, transfer and set over unto Trustee, for the ratable benefit of
Lenders, and their successors and assigns, with power of sale and right of entry and possession,
all of the following described land and interests in land, estates, easements, rights,
improvements, property, fixtures, equipment, furniture, furnishings, appliances, general
intangibles, and appurtenances, whether now or hereafter existing (collectively, the
“Property”):

          (a) All those tracts or parcels of land and easements more particularly described in
Exhibit “A” attached hereto and by this reference made a part hereof (the “Land”).

          (b) All present and future buildings, structures, parking areas, annexations and
improvements of every nature whatsoever now or hereafter situated on the Land (hereinafter referred
to as the “Improvements”) and all materials intended for construction, reconstruction,
alteration and repairs of the Improvements now or hereafter erected, all of which materials shall
be deemed to be included within the Improvements immediately upon the delivery thereof to the Land,
and all gas and electric fixtures, radiators, heaters, engines and machinery, boilers, ranges,
elevators and motors, plumbing and heating fixtures, incinerating, sprinkling, and waste removal
systems, carpeting and other floor coverings, fire extinguishers and any other safety equipment
required by governmental regulation or law, washers, dryers, water heaters, mirrors, mantels, air
conditioning apparatus, refrigerating plants, refrigerators, cooking apparatus and appurtenances,
storm windows and doors, window and door screens, awnings and storm sashes, which are or shall be
owned by Grantor and attached to said Improvements and all other furnishings, furniture, glassware,
tableware, uniforms, linen, drapes and curtains and related hardware and mounting devices, wall to
wall carpeting, radios, lamps, telephone systems, televisions and television systems, computer
systems, fixtures, machinery, equipment, apparatus, appliances, books and records, chattels,
inventory, accounts, farm products, consumer goods, general intangibles and personal property of
every kind and nature whatsoever now or hereafter owned by Grantor and located in, on or about, or
used or intended to be used with or in connection with the use, operation or enjoyment of the
Property, including all extensions, additions, improvements, betterments, after-acquired property,
renewals, replacements and substitutions, or proceeds from a permitted sale of any of the
foregoing, together with the benefit of any deposits or payments now or hereafter made by Grantor
or on behalf of Grantor, all of which are hereby declared and shall be deemed to be fixtures and
accessions to the Land and a part of the Property as between the parties hereto and all persons
claiming by, through or under them, and which shall be deemed to be a portion of the security for
the indebtedness herein described and to be secured by this Instrument.

          (c) All building materials, equipment, work in process or other personal property of
any kind, whether stored on the Land or elsewhere, which have been or later will be acquired for
the purpose of being delivered to, incorporated into or installed in or about the Land;

 

 

          (d) All easements, access rights, rights-of-way, strips and gores of land, vaults,
streets, ways, alleys, passages, sewer rights, waters, water courses, water rights and powers,
irrigation systems (including, without limitation, underground wiring, pipes, pumps and sprinkler
heads), minerals, flowers, plants, shrubs, crops, trees, timber, fences, signs, bridges, fountains,
monuments and other emblements now or hereafter located on the Land or under or above the same or
any part or parcel thereof, and all estates, rights, titles, interests, privileges, liberties,
servitudes, licenses, tenements, hereditaments and appurtenances, reversion and reversions,
remainder and remainders, whatsoever, in any way belonging, relating or appertaining to the Land or
any part thereof, or which hereafter shall in any way belong, relate or be appurtenant thereto,
whether now owned or hereafter acquired by Grantor.

          (e) All leases, tenancies, occupancies and licenses, whether oral or written
(collectively, the “Leases”), and all income, rents, issues, profits and revenues of the
Property from time to time accruing (including, without limitation, all payments under Leases, all
guarantees of the foregoing or letters of credit relating to the foregoing, lease termination
payments, proceeds of insurance, condemnation payments, tenant security, damage or other deposits
whether held by Grantor or in a trust account, escrow funds, fees, charges, rents, license fees,
accounts, royalties, security, damage or other deposits from time to time accruing, all payments
under working interests, production payments, royalties, overriding royalties, operating interests,
participating interest and other such entitlements, and all the estate, right, title, interest,
property, possession, claim and demand whatsoever at law, as well as in equity, of Grantor of, in
and to the same (collectively, the “Revenues”);

          (f) All insurance policies, building service, building maintenance, construction,
development, management, indemnity, and other similar agreements and contracts and subcontracts,
written or oral, express or implied, now or hereafter entered into, arising or in any manner
related to the purchase, construction, design, improvement, use, operation, ownership, occupation,
enjoyment, sale, conversion or other disposition (voluntary or involuntary) of the Property, or the
buildings and improvements now or hereafter located thereon, or any other interest in the Property,
or any combination thereof, property management agreements, cable television agreements, contracts
for the purchase of supplies, telephone service agreements, yellow pages or other advertising
agreements, sales contracts, construction contracts, architects agreements, general contract
agreements, design agreements, engineering agreements, technical service agreements, sewer and
water and other utility agreements, service contracts, agreements relating to the collection of
receivables or use of customer lists, all purchase options, option agreements, rights of first
refusal, contract deposits, earnest money deposits, prepaid items and payments due and to become
due thereunder, and further including all payment and performance bonds, labor, deposits,
assurances, construction guaranties, guaranties, warranties, indemnities and other undertakings,
architectural and engineering plans and specifications, drawings, surveys, soil reports,
engineering reports, inspection reports, environmental audits and other technical descriptions and
reports relating to the Property, renderings and models, permits, consents, approvals, licenses,
variances, agreements, contracts, building permits, purchase orders and equipment leases, personal
property leases, and all causes of action relating thereto.

          (g) All operating accounts maintained with any of Agent or the Lenders, Loan funds,
whether disbursed or not, reserves set forth in the Budget, deposit accounts, instruments, accounts
receivable, documents, causes of action, claims, names by which the Property or the improvements
thereon may be operated or known, all rights to carry on business under such names, all telephone
numbers or listings, all rights, interest and privileges of which Grantor may have in any capacity
under any covenants, restrictions or declarations now or hereafter relating to the Property or the
Improvements, and all notes or chattel paper now or hereafter arising from or by virtue of any
transactions relating to the Property or the Improvements located thereon and all customer lists,
other lists, and business information relating in any way to the Property or the Improvements or
the use thereof, whether now owned or hereafter acquired;

          (h) All assets related to the ownership or operation of the Property or the
Improvements now or hereafter erected thereon, including, without limitation, accounts (including,
without limitation, health-care-insurance receivables), chattel paper (whether tangible or
electronic), deposit accounts, documents, general intangibles (including, without limitation,
payment intangibles, and all current and after acquired registered copyrights, copyright rights,
advertising materials, web sites, and web pages, software and software licenses, registered
trademarks and service marks, trademark rights, trademark applications, service mark rights,
service mark applications, trade dress rights, company names, and all domain names, owned or used
in connection with the

7

 

Grantor’s business, and in each case all goodwill associated therewith), goods (including,
without limitation, inventory, property, possession, equipment, fixtures and accessions),
instruments (including, without limitation, promissory notes), investment property,
letter-of-credit rights, letters of credit, money, supporting obligations, as-extracted collateral,
timber to be cut and all proceeds and products of anything described or referred to above in this
Subsection (h), in each case as such terms are defined under the Uniform Commercial Code as in
effect in the applicable jurisdiction.

          (i) All cash funds, deposit accounts and other rights and evidence of rights to
cash, now or hereafter created or held by Trustee or Agent pursuant to this Instrument, the Loan
Agreement or any other of the Loan Documents.

          (j) All proceeds, products, substitutions and accessions of the foregoing of every
type.

          TO HAVE AND TO HOLD the Property and all parts, rights, members and appurtenances thereof, to
the use, benefit and behoof of Trustee for the ratable benefit of Agent and the Lenders and their
respective successors and assigns, IN FEE SIMPLE forever; and Grantor covenants that Grantor is
lawfully seized and possessed of the Property as aforesaid, and has good right to convey the same,
that the same is unencumbered except for those matters expressly set forth in Exhibit “B”
attached hereto and by this reference made a part hereof (the “Permitted Encumbrances”),
and that Grantor does warrant and will forever defend the title thereto against the claims of all
persons whomsoever, except as to those matters set forth in said Exhibit “B” attached
hereto.

          IN TRUST NEVERTHELESS to secure the following described obligations (collectively, the
“Secured Obligations”):

          (a) The debt evidenced by (i) that certain Note made by Grantor to the order of
KeyBank in the principal face amount of Seventy-Four Million and No/100 Dollars ($74,000,000.00),
which has been issued pursuant to the Loan Agreement and which is due and payable in full on or
before February 16, 2010, unless extended as provided in the Loan Agreement; and (ii) each other
note as may be issued under the Loan Agreement, each as originally executed, or if varied,
extended, supplemented, consolidated, amended, replaced, renewed, modified or restated from time to
time as so varied, extended, supplemented, consolidated, amended, replaced, renewed, modified or
restated (collectively, the “Note”).

          (b) The payment, performance and discharge of each and every obligation, covenant
and agreement of Grantor contained herein, of Grantor contained in the Loan Agreement, and of
Grantor in the other Loan Documents.

          (c) Any and all additional advances made by Agent or any Lender to protect or
preserve the Property or the lien and security title hereof in and to the Property, or for taxes,
assessments or insurance premiums as hereinafter provided (whether or not Grantor is the owner of
the Property at the time of such advances).

     (d) Any and all other indebtedness now or hereafter owing by Borrower to Agent or
any Lender pursuant to the terms of the Loan Agreement, whether now existing or hereafter arising
or incurred, however evidenced or incurred, whether express or implied, direct or indirect,
absolute or contingent, due or to become due, including, without limitation, all principal,
interest, fees, expenses, yield maintenance amounts and indemnification amounts, and all renewals,
modifications, consolidations, replacements and extensions thereof.

     (e) All costs and expenses incurred by the Trustee, Agent and the Lenders in
connection with the enforcement and collection of the Secured Obligations, including, without
limitation, all attorneys’ fees and disbursements, and all other such costs and expenses described
in and incurred pursuant to the Note, the Loan Agreement, the Guaranty, this Instrument, and the
other Loan Documents (collectively, the “Enforcement Costs”).

     Subject to Section 2.22 hereof, should the Secured Obligations secured by this Instrument be
paid in full and the obligation of the Lenders to make Loans under the Loan Agreement has
terminated, then this Instrument shall be released in accordance with the laws of the District of
Columbia.

8

 

     Grantor hereby further covenants and agrees with Trustee and Agent as follows:

ARTICLE 26

     26.1 Payment of Secured Obligations. Grantor will pay and perform or cause to be paid
and performed the Secured Obligations according to the tenor thereof and all other sums now or
hereafter secured hereby as the same shall become due.

     26.2 Funds for Impositions. Following receipt of written notice from Agent given
after the occurrence and during the continuance of an Event of Default, Grantor shall pay to Agent,
subject to Agent’s option under Section 1.03 hereof, on the days that monthly installments of
interest are payable under the Note, until the Note is paid in full, a sum (hereinafter referred to
as the “Funds”) reasonably estimated by Agent to provide an amount necessary for payment of
the following items in full thirty (30) days prior to when such items become due (hereinafter
collectively referred to as the “Impositions”): (a) the yearly real estate taxes, ad
valorem taxes, personal property taxes, assessments and betterments, and (b) the yearly premium
installments for the insurance covering the Property and required by the Loan Agreement. The
Impositions shall be reasonably estimated initially and from time to time by Agent on the basis of
assessments and bills and estimates thereof. The Funds shall be held by Agent in a separate
interest bearing account free of any liens or claims on the part of creditors of Grantor and as
part of the security for the Secured Obligations. Grantor shall pay all Impositions prior to
delinquency as required by Section 1.03 hereof. In the event Agent elects to reserve Funds as
permitted under this Section 1.02, within ten (10) days after Grantor furnishes Agent with
reasonably satisfactory evidence that Grantor has paid one or more of the items comprising the
Impositions, Agent shall reimburse Grantor (or the one paying the Impositions) therefor to the
extent of the Funds (plus accrued interest) then held by Agent. Alternatively, Agent shall apply
the Funds to pay the Impositions with respect to which the Funds were paid to the extent of the
Funds then held by Agent and provided Grantor has delivered to Agent the assessments or bills
therefor. Grantor shall be permitted to pay any Imposition early in order to take advantage of any
available discounts. Agent shall make no charge for so holding and applying the Funds or for
verifying and compiling said assessments and bills. The Funds are pledged as additional security
for the Secured Obligations, and may be applied, at Agent’s option and without notice to Grantor,
to the payment of the Secured Obligations upon the occurrence of any Event of Default. If at any
time the amount of the Funds held by Agent shall be less than the amount reasonably deemed
necessary by Agent to pay Impositions as such become due, Grantor shall pay to Agent any amount
necessary to make up the deficiency within fifteen (15) business days after notice from Agent to
Grantor requesting payment thereof. Upon payment and performance in full of the Secured
Obligations, Agent shall promptly refund to Grantor any Funds (plus accrued interest) then held by
Agent.

     26.3 Impositions, Liens and Charges. Grantor shall pay all Impositions and other
charges, if any, attributable to the Property prior to delinquency, and at Agent’s option during
the continuance of an Event of Default, Grantor shall pay in the manner hereafter provided under
this Section 1.03. Grantor shall, during continuance of an Event of Default, furnish to Agent all
bills and notices of amounts due under Section 1.03 as soon as received, and in the event Grantor
shall make payment directly, Grantor shall, as and when available, furnish to Agent receipts
evidencing such payments prior to the dates on which such payments are delinquent, subject to
Grantor’s right to contest taxes, assessments and other governmental charges as provided in the
Loan Agreement. Grantor shall promptly discharge (by bonding, payment or otherwise) any lien filed
against the Property or Grantor (including federal tax liens) and will keep and maintain the
Property free from the claims of all persons supplying labor or materials to the Property, subject
to Grantor’s right to contest the same as provided in the Loan Agreement. Grantor shall not claim
or be entitled to any credit against the taxable value of the Property by reason of this
Instrument, or any deduction in or credit on the Secured Obligations by reason of Impositions paid.

     26.4 Taxes, Liens and Other Charges.

          (a) In the event of the passage of any state, federal, municipal or other governmental law,
order, rule or regulation, subsequent to the date hereof, in any manner changing or modifying the
laws now in force governing the taxation of debts secured by deeds of trust or the manner of
collecting taxes so as to adversely affect Agent or the Lenders, Grantor will promptly pay any such
tax. If Grantor fails to make such payment within five (5) business days following written demand
therefor, or if, in the opinion of Agent, any such state, federal, municipal, or other governmental
law, order, rule or regulation prohibits Grantor from making such payment or would penalize

9

 

Agent or the Lenders if Grantor makes such payment or if, in the opinion of Agent, the making
of such payment could reasonably result in the imposition of interest beyond the maximum amount
permitted by applicable law, then the entire balance of the principal sums secured by this
Instrument and all interest accrued thereon shall, at the option of Agent, become immediately due
and payable upon sixty (60) days’ notice to Grantor.

          (b) Grantor will pay all taxes, liens, assessments and charges of every character including
all utility charges, whether public or private, already levied or assessed or that may hereafter be
levied or assessed upon or against the Property as required under the Loan Agreement.

     26.5 Insurance.

     Grantor shall procure for, deliver to and maintain for the benefit of Agent and Lenders the
insurance policies described in the Loan Agreement.

     26.6 Condemnation. If all or any portion of the Property shall be damaged or taken
through condemnation (which term when used in this Instrument shall include any damage or taking by
any governmental authority or any transfer by private sale in lieu thereof), either temporarily or
permanently, then all compensation, awards and other payments or relief thereof, shall be paid and
applied in accordance with terms and provisions of the Loan Agreement.

     26.7 Care, Use and Management of Property.

          (a) Grantor will keep, or cause to be kept, the roads and walkways, landscaping and all other
Improvements of any kind now or hereafter erected on the Land or any part thereof in good condition
and repair, will not commit or suffer any material waste, impairment or deterioration (ordinary
wear and tear excepted) and will not do or suffer to be done anything which will increase the risk
of fire or other hazard to the Property or any part thereof.

          (b) Except as permitted under the Loan Agreement, Grantor will not remove or demolish nor
alter the structural character of any building located on the Land or any fixtures or personal
property relating thereto except when incidental to the replacement of fixtures and personal
property with items of like kind and value or customary tenant improvements pursuant to Leases
approved or deemed approved pursuant to the Loan Agreement.

          (c) If the Property or any part thereof is materially damaged by fire or any other cause,
Grantor will give immediate written notice thereof to Agent.

          (d) To the extent permitted under the terms of the applicable Leases, Agent and each of the
Lenders or its representative is hereby authorized to enter upon and inspect the Property at any
time during normal business hours.

          (e) Grantor will promptly comply with all present and future laws, ordinances, rules and
regulations of any governmental authority, all restrictive covenants and other agreements affecting
the Property or relating to the operation thereof affecting the Property or any part thereof and
all licenses or permits affecting the Property or any part thereof, subject to Grantor’s right to
contest the same as provided in the Loan Agreement.

          (f) Grantor shall keep the Property, including the Improvements and the Personal Property (as
hereinafter defined), in good order, repair and tenantable condition and shall replace fixtures,
equipment, machinery and appliances on the Property when necessary to keep such items in good
order, repair, and tenantable condition (ordinary wear and tear excepted).

          (g) Grantor shall keep all franchises, trademarks, trade names, service marks and licenses and
permits necessary for the Grantor’s use and occupancy of the Property in good standing and in full
force and effect.

10

 

          (h) Unless required by applicable law or unless Agent has otherwise agreed in writing, Grantor
shall not allow changes in the nature of the occupancy or use from retail or office use with
respect to the first floor of the Property and office use with respect to the other floors of the
Property. Grantor shall not abandon the Property. Grantor shall not initiate, fail to contest or
acquiesce in a change in the zoning classification of the Property or subject the Property to
restrictive or negative covenants without Agent’s written consent, such consent not to be
unreasonably withheld, conditioned or delayed. Grantor shall comply with, observe and perform all
zoning and other laws affecting the Property, all agreements and restrictive covenants affecting
the Property, and all licenses and permits affecting the Property, subject to Grantor’s right to
contest compliance with laws to the extent permitted in the Loan Agreement.

          (i) Subject to the rights of tenants under the Leases, Agent may, at Grantor’s expense, make
or cause to be made reasonable entries upon and inspections of the Property as permitted in the
Loan Agreement, or at any other time when necessary or appropriate, in the sole reasonable
discretion of Agent, to protect or preserve the Property.

          (j) If all or any part of the Property shall be damaged by fire or other casualty or loss,
Grantor will promptly restore the Property to the equivalent of its original condition; and if a
part of the Property shall be damaged through condemnation, Grantor will promptly restore, repair
or alter the remaining portions of the Property in a manner satisfactory to Agent. Notwithstanding
the foregoing, Grantor shall not be obligated to so restore unless, in each instance, Agent agrees
to make available to Grantor (subject to the terms of the Loan Agreement) any net insurance or
condemnation proceeds actually received by Agent hereunder in connection with such casualty loss or
condemnation, to the extent such proceeds are required to defray the expense of such restoration;
provided, however, that the insufficiency of any such insurance or condemnation proceeds to defray
the entire expense of restoration shall in no way relieve Grantor of its obligation to restore.

     26.8 Leases and other Agreements Affecting Property.

          (a) As additional security for the Secured Obligations, Grantor, absolutely, presently and
unconditionally assigns and transfers to Agent all of Grantor’s right, title and interest in and to
the Leases and the Revenues, including those now due, past due or to become due by virtue of any of
the Leases for the occupancy or use of all or any part of the Property. Grantor hereby authorizes
Agent or Agent’s agents to collect the Revenues and hereby directs such tenants, lessees and
licensees of the Property to pay the Revenues to Agent or Agent’s agents; provided, however,
Grantor shall have a license (revocable upon the occurrence of an Event of Default) to collect and
receive the Revenues as trustee for the benefit of Agent, and apply the Revenues so collected to
the Secured Obligations, to the extent then due and payable, then to the payment of normal and
customary operating expenses for the Property which are then due and payable, with the balance, so
long as no Event of Default has occurred, to the account of Grantor. Grantor agrees that each and
every tenant, lessee and licensee of the Property may pay, and hereby irrevocably authorizes and
directs each and every tenant, lessee and licensee of the Property to pay, the Revenues to Agent or
Agent’s agents on Agent’s written demand therefor (which demand may be made by Agent at any time
after the occurrence of an Event of Default) without any obligation on the part of said tenant,
lessee or licensee to inquire as to the existence of an Event of Default and notwithstanding any
notice or claim of Grantor to the contrary, and Grantor agrees that Grantor shall have no right or
claim against said tenant, lessee or licensee for or by reason of any Revenues paid to Agent
following receipt of such written demand.

          (b) Grantor hereby covenants that Grantor has not executed any prior assignment of the Leases
or the Revenues, that Grantor has not performed, and will not perform, any acts and has not
executed, and will not execute, any instruments which would prevent Agent from exercising the
rights of the beneficiary of this Instrument, and that at the time of execution of this Instrument,
except as disclosed in the rent roll delivered to Agent on or about the date hereof or as provided
for in the Loan Agreement, there has been no anticipation or prepayment of any of the Revenues for
more than one (1) month prior to the due dates of such Revenues. Grantor further covenants that
Grantor will not hereafter collect or accept payment of any Revenues more than one (1) month prior
to the due dates of such Revenues.

          (c) Grantor agrees that neither the foregoing assignment of Leases and Revenues nor the
exercise of any of Agent’s rights and remedies under this Section or Article 2 hereof shall be
deemed to make Agent a mortgagee-in-possession or otherwise responsible or liable in any manner
with respect to the Leases, the Property

11

 

or the use, occupancy, enjoyment or operation of all or any portion thereof, unless and until
Agent, in person or by agent, assumes actual possession thereof. Grantor further agrees that the
appointment of any receiver for the Property by any court at the request of Agent or by agreement
with Grantor, or the entering into possession of any part of the Property by such receiver, shall
not be deemed to make Agent a mortgagee-in-possession or otherwise responsible or liable in any
manner with respect to the Leases, the Property or the use, occupancy, enjoyment or operation of
all or any portion thereof.

          (d) If Agent exercises its rights and remedies pursuant to this Section or Article 2 hereof,
all Revenues thereafter collected shall be applied in such order as Agent may elect in its
discretion to the reasonable costs of taking control of and managing the Property and collecting
the Revenues, including, but not limited to, reasonable attorneys’ fees actually incurred, fees,
premiums on receiver’s bonds, costs of repairs to the Property, premiums on insurance policies,
Impositions and other charges on the Property, and the costs of discharging any obligation or
liability of Grantor as landlord, lessor or licensor of the Property, or to the Secured
Obligations. Agent or any receiver shall have access to the books and records used in the
operation and maintenance of the Property and shall be liable to account only for those Revenues
actually received. Agent shall not be liable to Grantor, anyone claiming under or through Grantor
or anyone having an interest in the Property by reason of anything done or left undone by Agent
pursuant to this Section or Article 2 hereof, except in the event of Agent’s gross negligence or
willful misconduct. If the Revenues are not sufficient to meet the costs of taking control of and
managing the Property and collecting the Revenues, any monies reasonably expended by Agent for such
purposes shall become a portion of the Secured Obligations. Unless Agent and Grantor agree in
writing to other terms of payment, such amounts shall be payable within five (5) business days
following written notice from Agent to Grantor requesting payment thereof and shall bear interest
from the date of disbursement at the Default Rate stated in the Loan Agreement unless payment of
interest at such rate would be contrary to applicable law, in which event such amounts shall bear
interest at the highest rate which may be collected from Grantor under applicable law. The
entering upon and taking possession of and maintaining of control of the Property by Agent or any
receiver and the application of Revenues as provided herein shall not cure or waive any Event of
Default or invalidate any other right or remedy of Agent hereunder.

          (e) It is the intention of Agent and Grantor that the assignment effectuated by this
Instrument with respect to the Revenues shall be a direct and currently effective assignment and
shall not constitute merely an obligation to grant a lien, security interest or pledge for the
purpose of securing the Secured Obligations. In the event that a court of competent jurisdiction
determines that, notwithstanding such expressed intent of the parties, Agent’s interest in the
Revenues constitutes a lien on or security interest in or pledge of the Revenues, it is agreed and
understood that the forwarding of a notice to Borrower after the occurrence of an Event of Default
advising Borrower of the revocation of Borrower’s license to collect such Revenues, shall be
sufficient action by Agent to (i) perfect such lien on or security interest in or pledge of the
Revenues, (ii) take possession thereof and (iii) entitle Agent to immediate and direct payment of
the Revenues, for application as provided in this Instrument, all without the necessity of any
further action by Agent, including, without limitation, any action to obtain possession of the
Land, Improvements or any other portion of the Property.

     26.9 Leases of the Property.

          (a) Except as permitted in the Loan Agreement, Grantor shall not enter into any Lease of all
or any portion of the Property or amend, supplement or otherwise modify, or terminate or cancel, or
accept the surrender of, or consent to the assignment or subletting of, or grant any concessions to
or waive the performance of any obligations of any tenant, lessee or licensee under, any now
existing or future Lease of the Property, without the prior written consent of Agent. Grantor, at
Agent’s request, shall furnish Agent with executed copies of all Leases hereafter made of all or
any part of the Property as required by the Loan Agreement. Upon Agent’s request, Grantor shall
make a separate and distinct assignment to Agent, as additional security, of all Leases hereafter
made of all or any part of the Property.

          (b) There shall be no merger of the leasehold estates created by the Leases with the fee
estate of the Property without the prior written consent of Agent. Agent may at any time and from
time to time by specific written instrument intended for the purpose, unilaterally subordinate the
lien of this Instrument to any Lease, without

12

 

joinder or consent of, or notice to, Grantor, any tenant or any other Person, and notice is
hereby given to each tenant under a Lease of such right to subordinate. No such subordination
shall constitute a subordination to any lien or other encumbrance, whenever arising, or improve the
right of any junior lienholder. Nothing herein shall be construed as subordinating this Instrument
to any Lease.

          (c) Grantor hereby appoints Agent its attorney-in-fact, coupled with an interest, empowering
Agent to subordinate this Instrument to any Leases (which appointment shall not be exercised until
and unless an Event of Default shall have occurred and be continuing).

     26.10 Security Agreement.

          (a) THIS INSTRUMENT CREATES A LIEN ON THE PROPERTY. IN ADDITION, TO THE EXTENT THE PROPERTY IS
PERSONAL PROPERTY OR FIXTURES UNDER APPLICABLE LAW, THIS INSTRUMENT CONSTITUTES A SECURITY
AGREEMENT UNDER THE UCC (AS DEFINED BELOW) AND ANY OTHER APPLICABLE LAW AND IS FILED AS A FIXTURE
FILING. UPON THE OCCURRENCE OF AN EVENT OF DEFAULT, AGENT MAY, AT ITS OPTION, PURSUE ANY AND ALL
RIGHTS AND REMEDIES AVAILABLE TO A SECURED PARTY WITH RESPECT TO ANY PORTION OF THE PROPERTY,
AND/OR AGENT MAY, AT ITS OPTION, PROCEED AS TO ALL OR ANY PART OF THE PROPERTY IN ACCORDANCE WITH
AGENT’S RIGHTS AND REMEDIES WITH RESPECT TO THE LIEN CREATED BY THIS INSTRUMENT. THIS FINANCING
STATEMENT SHALL REMAIN IN EFFECT AS A FIXTURE FILING UNTIL THIS DEED OF TRUST IS RELEASED OR
SATISFIED OF RECORD.

          (b) Insofar as the machinery, apparatus, equipment, fittings, fixtures, building supplies and
materials, general intangibles and articles of personal property either referred to or described in
this Instrument, or in any way connected with the use and enjoyment of the Property is concerned,
Grantor grants unto Agent a security interest therein and this Instrument is hereby made and
declared to be a security agreement, encumbering each and every item of personal property (the
“Personal Property”) included herein, in compliance with the provisions of the Uniform
Commercial Code as enacted in the applicable jurisdiction as set forth in Section 3.04 below (the
“UCC”). A financing statement or statements reciting this Instrument to be a security
agreement, affecting all of said personal property aforementioned, shall be appropriately filed.
The remedies for any violation of the covenants, terms and conditions of the security agreement
herein contained shall be (i) as prescribed herein with respect to the Property, or (ii) as
prescribed by general law, or (iii) as prescribed by the specific statutory consequences now or
hereafter enacted and specified in said UCC, all at Agent’s sole election. Grantor and Agent agree
that the filing of such financing statement(s) in the records normally having to do with personal
property shall never be construed as in any way derogating from or impairing this declaration and
hereby stated intention of Grantor and Agent that everything used in connection with the production
of income from the Property and/or adapted for use therein and/or which is described or reflected
in this Instrument, is to the full extent provided by law, and at all times and for all purposes
and in all proceedings both legal or equitable shall be, regarded as part of the real estate
irrespective of whether (i) any such item is physically attached to the Improvements, (ii) serial
numbers are used for the better identification of certain items capable of being thus identified in
a recital contained herein, or (iii) any such item is referred to or reflected in any such
financing statement(s) so filed at any time. Similarly, the mention in any such financing
statement(s) of the rights in and to (1) the proceeds of any fire and/or hazard insurance policy,
or (2) any award in eminent domain proceedings for a taking or for loss of value, or (3) Grantor’s
interest as lessor in any present or future lease or rights to income growing out of the use and/or
occupancy of the Property, whether pursuant to lease or otherwise, shall never be construed as in
anyway altering any of the rights of Agent as determined by this Instrument or impugning the
priority of Agent’s lien granted hereby or by any other recorded document, but such mention in such
financing statement(s) is declared to be for the protection of Agent in the event any court shall
at any time hold with respect to the foregoing (1), (2) or (3), that notice of Agent’s priority of
interest to be effective against a particular class of persons, must be filed in the UCC records.

          (c) Grantor warrants that (i) each Grantor’s (that is, “Debtor’s”) correct legal name
(including, without limitation, punctuation and spacing) indicated on the public record of such
Grantor’s jurisdiction of organization, identity or corporate structure, residence or chief
executive office and jurisdiction of organization are as set forth in Subsection 1.10(c) hereof;
(ii) such Grantor (that is, “Debtor”) has been using or operating under said name, identity or
corporate structure without change for the time period set forth in Subsection 1.10(c) hereof, and
(iii) the location of the Personal Property secured by this Instrument is upon the Land. Grantor
covenants and

13

 

agrees that Grantor shall not change any of the matters addressed by clauses (i) or (iii) of
this Subsection 1.10(b) unless it has given Agent thirty (30) days prior written notice of any such
change and has executed or authorized at the request of Agent, such additional financing statements
or other instruments to be filed in such jurisdictions as Agent may deem necessary or advisable in
its sole discretion to prevent any filed financing statement from becoming misleading or losing its
perfected status.

          (d) The information contained in this Subsection 1.10(c) is provided in order that this
Instrument shall comply with the requirements of the Uniform Commercial Code, as enacted in the
District of Columbia, for instruments to be filed as financing statements. The names of the
“Debtor” and the “Secured Party”, the identity or corporate structure, jurisdiction of
organization, organizational number, federal tax identification number, and residence or chief
executive office of “Debtor”, and the time period for which “Debtor” has been using or operating
under said name and identity or corporate structure without change, are as set forth in Schedule 1
of Exhibit “C” attached hereto and by this reference made a part hereof; the mailing
address of the “Secured Party” from which information concerning the security interest may be
obtained, and the mailing address of “Debtor”, are as set forth in Schedule 2 of Exhibit
“C” attached hereto; and a statement indicating the types, or describing the items, of Personal
Property secured by this Instrument is set forth hereinabove.

          (e) Exhibit “C” correctly sets forth all names and tradenames that Grantor has used
within the last five years, and also correctly sets forth the locations of all of the chief
executive offices of Grantor over the last five years.

          (f) The Grantor hereby covenants and agrees that:

     a. Grantor shall not merge or consolidate into, or transfer any of the Property
to, any other person or entity except as permitted under the Loan Agreement.

     b. Grantor shall, at any time and from time to time, take such steps as Agent
may reasonably request for Agent (A) to obtain an acknowledgment, in form and
substance reasonably satisfactory to Agent, of any bailee having possession of any
of the Property, stating that the bailee holds possession of such Property on behalf
of Agent, (B) to obtain “control” of any investment property, deposit accounts,
letter-of-credit rights, or electronic chattel paper (as such terms are defined by
the UCC with corresponding provisions thereof defining what constitutes “control”
for such items of collateral), with any agreements establishing control to be in
form and substance reasonably satisfactory to Agent, and (C) otherwise to insure the
continued perfection and priority of the Agent’s security interest in any of the
Property and of the preservation of its rights therein. If Grantor shall at any
time, acquire a “commercial tort claim” (as such term is defined in the UCC) with
respect to the Property or any portion thereof, Grantor shall promptly notify Agent
thereof in writing, providing a reasonable description and summary thereof, and
shall execute a supplement to this Instrument in form and substance acceptable to
Agent granting a security interest in such commercial tort claim to Agent.

     c. Grantor hereby authorizes Agent, its counsel or its representative, at any
time and from time to time, to file financing statements, amendments and
continuations that describe or relate to the Property or any portion thereof in such
jurisdictions as Agent may deem necessary or desirable in order to perfect the
security interests granted by Grantor under this Instrument or any other Loan
Document, and such financing statements may contain, among other items as Agent may
deem advisable to include therein, the federal tax identification number of Grantor.

     d. Grantor shall not license, lease, sell or otherwise transfer any of the
general intangibles to any third party during the term of this Instrument and the
Loan Agreement without the prior written consent of the Agent (which consent may be
withheld in the Agent’s sole discretion); and the Grantor will continue to use all
trademarks, service marks and trade names in a consistent manner and shall take all
steps necessary to properly maintain any formal registrations on the general
intangibles, and to defend and enforce them, for the term of this Instrument and the
Loan Agreement.

14

 

          26.11 Further Assurances; After-Acquired Property. At any time and from time to time,
upon request by Agent, Grantor will make, execute and deliver or cause to be made, executed and
delivered, to Trustee and Agent and, where appropriate, cause to be recorded and/or filed and from
time to time thereafter to be rerecorded and/or refiled at such time and in such offices and places
as shall be deemed desirable by Agent, any and all such other and further deeds of trust, security
agreements, financing statements, notice filings, continuation statements, instruments of further
assurance, certificates and other documents as may, in the opinion of Agent, be necessary or
desirable in order to effectuate, complete, or perfect, or to continue and preserve (a) the
obligation of Grantor under the Guaranty, this Instrument and the other Loan Documents and (b) this
Instrument as a first and prior lien upon and security interest in and to all of the Property,
whether now owned or hereafter acquired by Grantor. Upon any failure by Grantor so to do, Agent may
make, execute, record, file, re-record and/or refile any and all such deeds of trust, security
agreements, financing statements, continuation statements, instruments, certificates, and documents
for and in the name of Grantor and Grantor hereby irrevocably appoints Agent the agent and
attorney-in-fact of Grantor so to do. The lien hereof will automatically attach, without further
act, to all after acquired property attached to and/or used in the operation of the Property or any
part thereof.

          26.12 Expenses. Grantor will pay or reimburse Agent, within five (5) business days of
written demand therefor, for all reasonable attorney’s fees, costs and expenses incurred by Agent
in any suit, action, legal proceeding or dispute of any kind in which Lenders, Agent or Trustee is
made a party or appears as party plaintiff or defendant, affecting or arising in connection with
the Secured Obligations secured hereby, this Instrument or the interest created herein, or the
Property, including, but not limited to, the exercise of the power of sale contained in this
Instrument, any condemnation action involving the Property or any action to protect the security
hereof; and any such amounts paid by Lenders, Agent or Trustee shall be added to the Secured
Obligations secured by the lien of this Instrument.

          26.13 Subrogation. Agent shall be subrogated to the claims and liens of all parties
whose claims or liens are discharged or paid with the proceeds of the Secured Obligations secured
hereby.

          26.14 Limit of Validity. If from any circumstances whatsoever fulfillment of any
provision of this Instrument, the Guaranty, the Loan Agreement, the Note or any other Loan
Document, at the time performance of such provision shall be due, shall be subject to the defense
of usury or otherwise violate applicable law concerning interest or other charges, then ipso facto
the obligation to be fulfilled shall be reduced to the limit, so that in no event shall any
exaction be possible under this Instrument, the Guaranty, the Note, the Loan Agreement or any other
Loan Document be subject to the defense of usury or otherwise violate applicable law concerning
interest or other charges that is in excess of the current limit, but such obligation shall be
fulfilled to the maximum limit permitted. The provisions of this Section 1.14 shall control every
other provision of this Instrument, the Guaranty, the Note, the Loan Agreement or any other Loan
Document.

          26.15 Conveyance of Property. Grantor hereby acknowledges to Agent that (a) the
identity and expertise of Grantor was and continues to be a material circumstance upon which Agent
has relied in connection with, and which constitute valuable consideration to Agent for, the
extending to Borrower of the loans evidenced by the Note and Loan Agreement, and (b) any change in
such identity or expertise could materially impair or jeopardize the security for the payment of
the Secured Obligations granted to Agent by this Instrument. Grantor therefore covenants and agrees
with Agent, as part of the consideration for the extending to Grantor of the loans evidenced by the
Note, that Grantor shall not convey, transfer, assign, further encumber or pledge any or all of its
interest in the Property except as permitted under the Loan Agreement.

ARTICLE 27

          27.1 Events of Default. The terms “Default” and “Event of Default” as used herein
shall have the following meanings:

  “Default” shall mean any event which, with the giving of notice or the lapse
of time, or both, would become an Event of Default.

15

 

“Event of Default” shall mean (a) any default in the payment of the
obligations of Grantor hereunder or of Grantor under any of the other Loan Documents
when the same shall become due and payable which is not cured within any grace or
notice and cure period provided in the Loan Agreement or such other Loan Documents,
if any, subject to any limitations in the Loan Agreement on the right of Grantor to
receive notices of default, or (b) any default in the performance of any other
obligations of Grantor hereunder which is not cured within any grace or cure period
provided in the Loan Agreement (it being acknowledged by Grantor that no such cure
period is provided with respect to a failure to maintain insurance as required in
Section 1.05, any default under Section 1.08, any default under Section 1.15, or any
default excluded from any provision for a grace period or cure of defaults contained
in the Loan Agreement, the Security Documents (as defined in the Loan Agreement) or
any other agreement evidencing or securing the Secured Obligations), or (c) any
representation or warranty of Grantor hereunder proving to be false or incorrect in
any material respect upon the date when made or deemed to have been repeated, or (d)
any default in the performance of the obligations of Grantor or any other Person
under any of the Security Documents beyond the expiration of any applicable notice
and cure period, (e) the occurrence of any “Event of Default” under the Loan
Agreement, (f) any amendment to or termination of a financing statement naming
Grantor as debtor and Agent as secured party, or any correction statement with
respect thereto, is filed in any jurisdiction by, or caused by, or at the instance
of Grantor or by, or caused by, or at the instance of any principal, member, general
partner or officer of Grantor (collectively, “Grantor Party”) without the prior
written consent of Agent; or (g) any amendment to or termination of a financing
statement naming Grantor as debtor and Agent as secured party, or any correction
statement with respect thereto, is filed in any jurisdiction by any party other than
an Grantor Party or Agent or Agent’s counsel without the prior written consent of
Agent and Grantor fails to use its best efforts to cause the effect of such filing
to be completely nullified to the reasonable satisfaction of Agent within ten (10)
days after notice to Grantor thereof.

     27.2 Acceleration of Maturity. If an Event of Default shall have occurred and be
continuing, then the entire Secured Obligations secured hereby shall, at the option of Agent and as
permitted by the terms of the Loan Agreement, immediately become due and payable without notice or
demand except as required by law, time being of the essence of this Instrument.

     27.3 Right to Enter and Take Possession.

          (a) If an Event of Default shall have occurred and be continuing, Grantor, upon demand of
Agent, shall forthwith surrender to Agent the actual possession of the Property, and if and to the
extent permitted by law, Agent itself, or by such officers or agents as it may appoint, may enter
and take possession of all the Property (or such portion or portions as Agent may select) without
the appointment of a receiver, or an application therefor, and may exclude Grantor and its agents
and employees wholly therefrom, and may have joint access with Grantor to the books, papers and
accounts of Grantor.

          (b) If Grantor shall for any reason fail to surrender or deliver the Property or any part
thereof after such demand by Agent, Agent may obtain a judgment or decree conferring upon Agent the
right to immediate possession or requiring Grantor to deliver immediate possession of the Property
to Agent. Grantor will pay to Agent, upon demand, all expenses of obtaining such judgment or
decree, including reasonable compensation to Agent, its attorneys and agents; and all such expenses
and compensation shall, until paid, be secured by the lien of this Instrument.

          (c) Upon every such entering upon or taking of possession, Agent may hold, store, use,
operate, manage and control the Property and conduct the business thereof and, from time to time,
(i) make all necessary and proper maintenance, repairs, renewals, replacements, additions,
betterments and improvements thereto and thereon and purchase or otherwise acquire additional
fixtures, personalty and other property necessary to maintain the good condition of the Property or
to perform obligations with respect to the Property or to comply with any of the Leases; (ii)
insure or keep the Property insured; (iii) lease, manage and operate the Property and exercise all
the rights and powers of Grantor to the same extent as Grantor could in its own name or otherwise
with respect to the same; and (iv) enter into any and all agreements with respect to the exercise
by others of any of the powers

16

 

herein granted Agent, all as Agent from time to time may determine to be in its best interest.
Agent may collect and receive all the rents, issues, profits and revenues from the Property,
including those past due as well as those accruing thereafter, and, after deducting (1) all
expenses of taking, holding, managing and operating the Property (including compensation for the
services of all persons employed for such purposes); (2) the cost of all such maintenance, repairs,
renewals, replacements, additions, betterments, improvements, purchases and acquisitions; (3) the
cost of such insurance; (4) such taxes, assessments and other similar charges as Agent may at its
option pay; (5) other proper charges upon the Property or any part thereof; and (6) the reasonable
compensation, expenses and disbursements of the attorneys and agents of Agent, Agent shall apply
the remainder of the monies and proceeds so received by Agent in accordance with Section 21.14 of
the Loan Agreement. Agent shall have no obligation to discharge any duties of a landlord to any
tenant or to incur any liability as a result of any exercise by Agent of any rights under this
Instrument or otherwise. Agent shall not be liable for any failure to collect rents, issues,
profits and revenues from the Property, nor shall Agent be liable to account for any such rents,
issues, profits or revenues unless actually received by Agent.

          (d) Whenever all that is due upon the Secured Obligations and under any of the terms,
covenants, conditions and agreements of this Instrument shall have been paid and all Events of
Default cured, Agent shall surrender possession of the Property to Grantor, its successors or
assigns. The same right of taking possession, however, shall exist if any subsequent Event of
Default shall occur and be continuing.

     27.4 Performance by Agent. If there shall be a Default in the payment, performance or
observance of any term, covenant or condition of this Instrument, Agent may, so long as such
Default continues, at its option, pay, perform or observe the same, and all payments made or costs
or expenses incurred by Agent in connection therewith, shall be secured hereby and shall be, upon
demand, immediately repaid by Grantor to Agent with interest thereon at the Default Rate. Agent
shall be the sole judge of the necessity for any such actions and of the amounts to be paid. Agent
is hereby empowered to enter and to authorize others to enter upon the Land or any part thereof for
the purpose of performing or observing any such defaulted term, covenant or condition without
thereby becoming liable to Grantor or any person in possession holding under Grantor.

     27.5 Receiver. If an Event of Default shall have occurred and be continuing, Agent,
upon application to a court of competent jurisdiction, shall be entitled as a matter of strict
right without regard to the occupancy or value of any security for the Secured Obligations secured
hereby or the solvency of any party bound for its payment, to the appointment of a receiver to take
possession of and to operate the Property (or such portion or portions as Agent may select) and to
collect and apply the rents, issues, profits and revenues thereof. The receiver shall have all of
the rights and powers permitted under the laws of the District of Columbia. Grantor will pay to
Agent within five (5) days following written demand all reasonable expenses, including receiver’s
fees, attorney’s fees, costs and agent’s compensation, incurred pursuant to the provisions of this
Section 2.05, and all such expenses shall be secured by this Instrument.

     27.6 Power of Sale. At any time after and during the continuance of an Event of
Default, Agent shall be entitled to invoke any and all of the rights and remedies described below
in 2.06(a) — (d), in addition to all other rights and remedies available to Agent at law or in
equity. All of such rights and remedies shall be cumulative, and the exercise of any one or more
of them shall not constitute an election of remedies. 

          (a) Direct and empower Trustee to take possession of any or all of the Property and to sell
the Property, in whole or in part, and in the case of default of any purchaser or purchasers,
resell all the Property as an entirety, or in such parcels as Agent shall in writing request, or,
in the absence of such request, as Trustee may determine, at public auction at some convenient
place in the District of Columbia, at such time, in such manner and upon such terms as Trustee may
fix. The notice of sale shall state the time and place of the sale, shall contain a brief general
description of the Property to be sold, and shall be sufficiently given if published in either The
Washington Post or other publications where such notices are customarily published or in the
place(s) where such sale is to take place, such advertisement of sale to be published five (5)
times every other day (excluding Sundays and holidays) over a ten business day period prior to the
day of said sale, subject to compliance with the requirements formerly codified at Section
45-715(b) of the D.C. Code, or any recodified, revised or successor provision as may hereafter take
effect, and Agent or Trustee shall cause further public advertisement to be made as they deem
advisable. Any such sale may be adjourned by Trustee by announcement at the time and place
appointed for such sale or for such adjourned sale(s), and, without further notice or publication,
such sale may be made at the time and place to which

17

 

same shall be so adjourned. Upon the completion of any sale, Trustee shall execute and
deliver to the purchaser(s) a good and sufficient deed of conveyance, or assignment and transfer,
lawfully conveying, assigning and transferring, without warranty, the property sold.

          (b) If any or all of the Property or any estate or interest therein is to be sold under the
provisions of this Instrument, by virtue of a judicial sale or otherwise, it may be sold at public
auction, as an entirety or in one or more parcels, by one sale or by several sales held at one time
or at different times, with such postponement of any such sale as Trustee may deem appropriate and
without regard to any right of Grantor or any other person to the marshalling of assets. Trustee
shall hold such sale or sales at such time or times and at such place or places, and shall make
sales upon such terms and conditions and after such previous public notice as required by law and
as Trustee may deem appropriate. Agent may bid and become the purchaser at any such sale, and
shall, upon presentation of the Note or a true copy thereof at such sale, be credited for the
unpaid balance due under the Note and any interest accrued and unpaid thereon, and any other
amounts secured hereunder or such portion of such unpaid balance or interest or other sums
evidenced by the Note and secured by this Instrument as Agent may specify, against any price bid by
Agent thereat. The terms of sale being complied with, Trustee shall convey, in the form of a
Trustee’s Deed, to and at the cost of the purchaser at such sale Grantor’s interest in so much of
the Property as is so sold, free of and discharged from all estate, right, title or interest of
Grantor at law or in equity, such purchaser being hereby discharged from all liability to see to
the application of the purchase money.

          (c) Upon sale of Grantor’s interest in any or all of the Property, whether under the power of
sale herein granted, or by other foreclosure or judicial proceedings, Trustee shall apply the
proceeds of such sale, together with any other sum then held as security hereunder or due under any
of the provisions hereof as part of the security of the Note after paying all expenses of obtaining
possession of the Property and all expenses of sale, including attorneys’ fees and a commission to
the party making the sale equal to the commission allowed to trustees for making sales of property
under orders or decrees of a court having competent jurisdiction, and all taxes and assessments
which Trustee or Agent deem it advisable or expedient to pay and all sums advanced, with interest
thereon at the Default Rate (as such term is defined in the Note), as herein provided to the
payment of the Secured Obligations and interest thereon to the date of payment, then due and owing
by Grantor to Agent, including the paying over the surplus, if any, less the expense, if any, of
obtaining possession, to Grantor or any person entitled thereto upon the surrender and delivery to
the purchaser of possession of the Property.

          (d) Immediately upon the first insertion of any advertisement or notice of any such sale,
there shall become due and owing by Grantor all expenses incident to such advertisement or notice,
all court costs and all expenses incident to any foreclosure proceedings brought under this
Instrument or otherwise in connection with such sale, and a commission equal to one-half of one
percent (0.5%) of the total amount of the Secured Obligations then due and owing, such commission
being the commission allowed to trustees for making sales of property under orders or decrees of a
court having competent jurisdiction, and no party shall be required to receive the principal,
interest and prepayment fee only of the Secured Obligations in satisfaction thereof unless it is
accompanied by a tender of payment of such expenses, costs and commissions. The foregoing shall
not be in derogation of the commission payable under Section 42-818(b) of the D.C. Code.

Notwithstanding the relationship of the parties constituting Grantor, and as an express inducement
to Agent to make the loan or loans secured hereby, and for other good and valuable consideration to
Grantor in hand paid, receipt whereof is hereby acknowledged, Grantor does hereby waive for itself
(as well as all of its partners), its successors and assigns, in the event of foreclosure of this
Instrument, any equitable right, otherwise available to it, in respect to marshalling of assets
hereunder. In the event of a sale of part of, or interest in, the Property in satisfaction of part
of the debt secured by this Instrument, this Instrument shall, as to the remaining part of, or
interest in, the Property, continue as a lien for the remainder of the debt.

     27.7 Purchase by Agent. Upon any foreclosure sale, Agent, on behalf of the Lenders,
may bid for and purchase the Property and shall be entitled to apply all or any part of the Secured
Obligations secured hereby as a credit to the purchase price.

     27.8 Application of Proceeds of Sale. The proceeds received by Agent as a result of a
foreclosure sale of the Property or the exercise of any other rights or remedies hereunder shall be
applied in the manner provided for in the Loan Agreement.

18

 

     27.9 Grantor as Tenant Holding Over. In the event of any such foreclosure sale by
Agent, Grantor shall be deemed a tenant holding over and shall forthwith deliver possession to the
purchaser or purchasers at such sale or be summarily dispossessed according to provisions of law
applicable to tenants holding over.

     27.10 Waiver of Appraisement, Valuation, Stay, Extension and Redemption Laws. Grantor
agrees, to the full extent permitted by law, that in case of a Default or Event of Default, neither
Grantor nor anyone claiming through or under it shall or will set up, claim or seek to take
advantage of any appraisement, valuation, stay, extension, homestead, exemption or redemption laws
now or hereafter in force, in order to prevent or hinder the enforcement or foreclosure of this
Instrument, or the absolute sale of the Property, or the final and absolute putting into possession
thereof, immediately after such sale, of the purchasers thereat, and Grantor, for itself and all
who may at any time claim through or under it, hereby waives to the full extent that it may
lawfully so do, the benefit of all such laws, and any and all right to have the assets comprised in
the security intended to be created hereby marshaled upon any foreclosure of the lien hereof.

     27.11 Waiver of Homestead. Grantor hereby waives and renounces all homestead and
exemption rights provided for by the Constitution and the laws of the United States and of any
state, in and to the Property as against the collection of the Secured Obligations, or any part
hereof.

     27.12 Leases; Licensees. Agent, at its option, is authorized to foreclose this
Instrument subject to the rights of any tenants and licensees of the Property, and the failure to
make any such tenants or licensees parties to any such foreclosure proceedings and to foreclose
their rights will not be, nor be asserted by Grantor to be a defense to any proceedings instituted
by Agent to collect the sums secured hereby.

     27.13 Discontinuance of Proceedings and Restoration of the Parties. In case Agent
shall have proceeded to enforce any right, power or remedy under this Instrument by foreclosure,
entry or otherwise, and such proceedings shall have been discontinued or abandoned for any reason,
or shall have been determined adversely to Agent, then and in every such case Grantor and Agent
shall be restored to their former positions and rights hereunder, and all rights, powers and
remedies of Agent shall continue as if no such proceeding had been taken.

     27.14 Remedies Cumulative. No right, power or remedy conferred upon or reserved to
Agent by this Instrument is intended to be exclusive of any other right, power or remedy, but each
and every such right, power and remedy shall be cumulative and concurrent and may be exercised
against Grantor as Agent may select and shall be in addition to any other right, power and remedy
given hereunder or now or hereafter existing at law or in equity or by statute.

     27.15 Waiver.

          (a) No delay or omission of Agent or of any Lender to exercise any right, power or remedy
accruing upon any Default or Event of Default shall exhaust or impair any such right, power or
remedy or shall be construed to be a waiver of any such Default or Event of Default, or
acquiescence therein; and every right, power and remedy given by this Instrument to Agent may be
exercised from time to time and as often as may be deemed expedient by Agent. No consent or
waiver, expressed or implied, by Agent to or of any Default or Event of Default by Grantor in the
performance of the obligations thereof hereunder shall be deemed or construed to be a consent or
waiver to or of any other Default or Event of Default in the performance of the same or any other
obligations of Grantor hereunder. Failure on the part of Lenders to complain of any act or failure
to act or to declare a Default or Event of Default, irrespective of how long such failure
continues, shall not constitute a waiver by any Lender of its rights hereunder or impair any
rights, powers or remedies consequent on any Default or Event of Default by Grantor.

          (b) If Lenders or Agent on behalf of the Lenders, (i) grant forbearance or an extension of
time for the payment of any sums secured hereby; (ii) take other or additional security for the
payment of any sums secured hereby; (iii) waive or do not exercise any right granted herein or in
the Note, the Loan Agreement or any other Loan Document; (iv) release any part of the Property from
the lien of this Instrument or otherwise change any of the terms, covenants, conditions or
agreements of the Note, this Instrument or any other Loan Document; (v) consent to the filing of
any map, plat or replat affecting the Property; (vi) consent to the granting of any easement or
other right affecting the Property; or (vii) make or consent to any agreement subordinating the
lien

19

 

hereof, any such act or omission shall not release, discharge, modify, change or affect the original liability
under the Note, the Loan Agreement, the Guaranty, this Instrument or any other obligation of
Grantor, or any subsequent purchaser of the Property or any part thereof, or any maker, co-signer,
endorser, surety or guarantor; nor shall any such act or omission preclude Agent from exercising
any right, power or privilege herein granted or intended to be granted in the event of any Default
then made or of any subsequent Default; nor, except as otherwise expressly provided in an
instrument or instruments executed by Agent, shall the lien of this Instrument be altered thereby.
In the event of the sale or transfer by operation of law or otherwise of all or any part of the
Property, Agent, without notice, is hereby authorized and empowered to deal with any such vendee or
transferee with reference to the Property or the Secured Obligations secured hereby, or with
reference to any of the terms, covenants, conditions or agreements hereof, as fully and to the same
extent as it might deal with the original parties hereto and without in any way releasing or
discharging any liabilities, obligations or undertakings.

     27.16 Suits to Protect the Property. Agent shall have power (a) to institute and
maintain such suits and proceedings as it may deem expedient to prevent any impairment of the
Property by any acts which may be unlawful or in violation of this Instrument, (b) to preserve or
protect its interest in the Property and in the rents, issues, profits and revenues arising
therefrom, and (c) to restrain the enforcement of or compliance with any legislation or other
governmental enactment, rule or order that may be unconstitutional or otherwise invalid, if the
enforcement of or compliance with such enactment, rule or order would impair the security hereunder
or be prejudicial to the interest of Lenders.

     27.17 Agent May File Proofs of Claim. In the case of any receivership, insolvency,
bankruptcy, reorganization, arrangement, adjustment, composition or other proceedings affecting
Grantor, its creditors or its property, Agent, to the extent permitted by law, shall be entitled to
file such proofs of claim and other documents as may be necessary or advisable in order to have the
claims of Agent allowed in such proceedings for the entire amount due and payable by Grantor under
this Instrument at the date of the institution of such proceedings and for any additional amount
which may become due and payable by Grantor hereunder after such date.

     27.18 WAIVER OF GRANTOR’S RIGHTS. BY EXECUTION OF THIS INSTRUMENT, GRANTOR EXPRESSLY:
(A) ACKNOWLEDGES THE RIGHT OF AGENT AND/OR LENDERS TO ACCELERATE THE SECURED OBLIGATIONS AND THE
POWER OF AGENT TO CAUSE TRUSTEE TO SELL THE PROPERTY BY NONJUDICIAL FORECLOSURE UPON DEFAULT BY
GRANTOR WITHOUT ANY JUDICIAL HEARING AND WITHOUT ANY NOTICE OTHER THAN SUCH NOTICE (IF ANY) AS IS
SPECIFICALLY REQUIRED TO BE GIVEN UNDER THE PROVISIONS OF THIS INSTRUMENT OR BY LAW; (B) TO THE
FULL EXTENT PERMITTED BY LAW, WAIVES ANY AND ALL RIGHTS WHICH GRANTOR MAY HAVE UNDER THE
CONSTITUTION OF THE UNITED STATES (INCLUDING, WITHOUT LIMITATION, THE FIFTH AND FOURTEENTH
AMENDMENTS THEREOF), THE VARIOUS PROVISIONS OF THE CONSTITUTIONS FOR THE SEVERAL STATES, OR BY
REASON OF ANY OTHER APPLICABLE LAW, TO NOTICE AND TO JUDICIAL HEARING PRIOR TO THE EXERCISE BY
AGENT OF ANY RIGHT OR REMEDY HEREIN PROVIDED TO AGENT, EXCEPT SUCH NOTICE (IF ANY) AS IS
SPECIFICALLY REQUIRED TO BE PROVIDED IN THIS INSTRUMENT OR BY APPLICABLE LAW; (C) ACKNOWLEDGES THAT
GRANTOR HAS READ THIS INSTRUMENT AND THE OTHER LOAN DOCUMENTS AND ANY AND ALL QUESTIONS REGARDING
THE LEGAL EFFECT OF THIS INSTRUMENT AND THE OTHER LOAN DOCUMENTS AND THEIR PROVISIONS HAVE BEEN
EXPLAINED FULLY TO GRANTOR AND GRANTOR HAS CONSULTED WITH COUNSEL OF GRANTOR’S CHOICE PRIOR TO
EXECUTING THIS INSTRUMENT; AND (D) ACKNOWLEDGES THAT ALL WAIVERS OF THE AFORESAID RIGHTS OF GRANTOR
HAVE BEEN MADE KNOWINGLY, INTENTIONALLY AND WILLINGLY BY GRANTOR AS PART OF A BARGAINED FOR LOAN
TRANSACTION.

     27.19 Claims Against Agent and Lenders. No action at law or in equity shall be
commenced, or allegation made, or defense raised, by Grantor against Agent or the Lenders for any
claim under or related to this Instrument, the Note, the Loan Agreement, the Guaranty or any other
instrument, document, transfer, conveyance, assignment or loan agreement given by Grantor with
respect to the Secured Obligations secured hereby, or related to the conduct of the parties
thereunder, unless written notice of such claim, expressly setting forth the particulars of the
claim alleged by Grantor, shall have been given to Agent within sixty (60) days from and after the
initial awareness of Grantor of the event, omission or circumstances forming the basis of Grantor
for such claim. Any failure by Grantor to timely provide such written notice to Agent shall
constitute a waiver by Grantor of such claim.

20

 

     27.20 [Intentionally Omitted].

     27.21 Indemnification; Subrogation; Waiver of Offset.

          (a) Grantor shall indemnify, defend and hold Agent and the Lenders harmless for, from and
against any and all liability, Secured Obligations, losses, damages, penalties, claims, actions,
suits, costs and expenses (including Agent’s reasonable attorneys’ fees, together with reasonable
appellate counsel fees, if any) of whatever kind or nature which may be asserted against, imposed
on or incurred by Agent or the Lenders in connection with the Secured Obligations, this Instrument,
the Property, or any part thereof, or the exercise by Agent of any rights or remedies granted to it
under this Instrument; provided, however, that nothing herein shall be construed to obligate
Grantor to indemnify, defend and hold harmless Agent or the Lenders for, from and against any and
all liabilities, Secured Obligations, losses, damages, penalties, claims, actions, suits, costs and
expenses asserted against, imposed on or incurred by Agent or a Lender by reason of such Person’s
willful misconduct or gross negligence if a judgment is entered against Agent or a Lender by a
court of competent jurisdiction after the expiration of all applicable appeal periods.

          (b) If Agent or a Lender is made a party defendant to any litigation or any claim is
threatened or brought against Agent or a Lender concerning the Secured Obligations, this
Instrument, the Property, or any part thereof, or any interest therein, or the construction,
maintenance, operation or occupancy or use thereof, then Grantor shall indemnify, defend and hold
such Person harmless for, from and against all liability by reason of said litigation or claims,
including reasonable attorneys’ fees (together with reasonable appellate counsel fees, if any) and
expenses incurred by such Person in any such litigation or claim, whether or not any such
litigation or claim is prosecuted to judgment; provided, however, that nothing in this Section
2.21(b) shall be construed to obligate Grantor to indemnify, defend and hold harmless Agent or a
Lender for, from and against any and all liabilities or claims imposed on or incurred by such
Person by reason of such Person’s willful misconduct or gross negligence if a judgment is entered
against such Person by a court of competent jurisdiction after expiration of all applicable appeal
periods. If Agent commences an action against Grantor to enforce any of the terms hereof or to
prosecute any breach by Grantor of any of the terms hereof or to recover any sum secured hereby,
Grantor shall pay to Agent its reasonable attorneys’ fees (together with reasonable appellate
counsel, fees, if any) and expenses. The right to such attorneys’ fees (together with reasonable
appellate counsel fees, if any) and expenses shall be deemed to have accrued on the commencement of
such action, and shall be enforceable whether or not such action is prosecuted to judgment. If
Grantor breaches any term of this Instrument, Agent may engage the services of an attorney or
attorneys to protect its rights hereunder, and in the event of such engagement following any breach
by Grantor, Grantor shall pay Agent reasonable attorneys’ fees (together with reasonable appellate
counsel fees, if any) and expenses incurred by Agent, whether or not an action is actually
commenced against Grantor by reason of such breach. All references to “attorneys” in this
Subsection and elsewhere in this Instrument shall include without limitation any attorney or law
firm engaged by Agent and Agent’s in-house counsel, and all references to “fees and expenses” in
this Subsection and elsewhere in this Instrument shall include without limitation any fees of such
attorney or law firm and any allocation charges and allocation costs of Agent’s in-house counsel.

          (c) A waiver of subrogation shall be obtained by Grantor from its insurance carrier and,
consequently, Grantor waives any and all right to claim or recover against Agent, the Lenders and
each of its officers, employees, agents and representatives, for loss of or damage to Grantor, the
Property, Grantor’s property or the property of others under Grantor’s control from any cause
insured against or required to be insured against by the provisions of this Instrument.

          (d) ALL SUMS PAYABLE BY GRANTOR HEREUNDER SHALL BE PAID WITHOUT NOTICE (EXCEPT AS MAY
OTHERWISE BE PROVIDED HEREIN OR REQUIRED BY LAW), DEMAND, COUNTERCLAIM, SETOFF, DEDUCTION OR
DEFENSE AND WITHOUT ABATEMENT, SUSPENSION, DEFERMENT, DIMINUTION OR REDUCTION, AND THE SECURED
OBLIGATIONS AND LIABILITIES OF GRANTOR HEREUNDER SHALL IN NO WAY BE RELEASED, DISCHARGED OR
OTHERWISE AFFECTED BY REASON OF: (I) ANY DAMAGE TO OR DESTRUCTION OF OR ANY CONDEMNATION OR SIMILAR
TAKING OF THE PROPERTY OR ANY PART THEREOF; (II) ANY RESTRICTION OR PREVENTION OF OR INTERFERENCE
WITH ANY USE OF THE PROPERTY OR ANY PART THEREOF; (III) ANY TITLE DEFECT OR ENCUMBRANCE OR ANY
EVICTION FROM THE LAND OR THE IMPROVEMENTS ON THE LAND OR ANY PART THEREOF BY TITLE PARAMOUNT OR
OTHERWISE;

21

 

(IV) ANY BANKRUPTCY, INSOLVENCY, REORGANIZATION, COMPOSITION, ADJUSTMENT, DISSOLUTION,
LIQUIDATION, OR OTHER LIKE PROCEEDING RELATING TO AGENT OR THE LENDERS, OR ANY ACTION TAKEN WITH
RESPECT TO THIS INSTRUMENT BY ANY TRUSTEE OR BY ANY RECEIVER OF AGENT, OR BY ANY COURT, IN SUCH
PROCEEDING; (V) ANY CLAIM WHICH GRANTOR HAS, OR MIGHT HAVE, AGAINST AGENT OR THE LENDERS; (VI) ANY
DEFAULT OR FAILURE ON THE PART OF AGENT OR THE LENDERS TO PERFORM OR COMPLY WITH ANY OF THE TERMS
HEREOF OR OF ANY OTHER AGREEMENT WITH GRANTOR; OR (VII) ANY OTHER OCCURRENCE WHATSOEVER, WHETHER
SIMILAR OR DISSIMILAR TO THE FOREGOING, WHETHER OR NOT GRANTOR SHALL HAVE NOTICE OR KNOWLEDGE OF
ANY OF THE FOREGOING. GRANTOR WAIVES ALL RIGHTS NOW OR HEREAFTER CONFERRED BY STATUTE OR OTHERWISE
TO ANY ABATEMENT, SUSPENSION, DEFERMENT, DIMINUTION, OR REDUCTION OF ANY SUM SECURED HEREBY AND
PAYABLE BY GRANTOR.

     27.22 Future Advances. The total amount of indebtedness secured hereby may increase or
decrease from time to time, but the total unpaid principal balance of indebtedness secured hereby
(including disbursements that the Lender may, but shall not be obligated to, make under this
Instrument, the Loan Documents or any other document with respect thereto) at any one time
outstanding may be substantially less but shall not exceed Seventy-Four Million and No/100 Dollars
($74,000,000.00), plus interest thereon, and any disbursements made for the enforcement of this
Instrument and any remedies hereunder, payment of taxes, special assessments, utilities or
insurance on the Property and interest on such disbursements and all disbursements by Agent
pursuant to applicable law (all such indebtedness being hereinafter referred to as the maximum
amount secured hereby). This Instrument shall be valid and have priority to the extent of the
maximum amount secured hereby over all subsequent liens and encumbrances, including statutory
liens, excepting solely taxes and assessments levied on the Property given priority by law.

     27.23 WAIVER OF TRIAL BY JURY. GRANTOR HEREBY KNOWINGLY, VOLUNTARILY AND
INTENTIONALLY WAIVES ANY RIGHT THAT IT MAY HAVE TO A TRIAL BY JURY IN ANY LITIGATION ARISING IN ANY
WAY IN CONNECTION WITH THIS INSTRUMENT, THE NOTE, OR ANY OF THE OTHER LOAN DOCUMENTS, THE LOAN OR
ANY OTHER STATEMENTS OR ACTIONS OF GRANTOR OR AGENT. GRANTOR ACKNOWLEDGES THAT IT HAS BEEN
REPRESENTED IN THE SIGNING OF THIS INSTRUMENT AND IN THE MAKING OF THIS WAIVER BY INDEPENDENT LEGAL
COUNSEL SELECTED OF ITS OWN FREE WILL, AND THAT IT HAS DISCUSSED THIS WAIVER WITH SUCH LEGAL
COUNSEL. GRANTOR FURTHER ACKNOWLEDGES THAT (i) IT HAS READ AND UNDERSTANDS THE MEANING AND
RAMIFICATIONS OF THIS WAIVER, (ii) THIS WAIVER IS A MATERIAL INDUCEMENT FOR AGENT TO MAKE THE LOAN,
ENTER INTO THIS INSTRUMENT AND EACH OF THE OTHER LOAN DOCUMENTS, AND (iii) THIS WAIVER SHALL BE
EFFECTIVE AS TO EACH OF SUCH OTHER LOAN DOCUMENTS AS IF FULLY INCORPORATED THEREIN.

ARTICLE 28

     28.1 Successors and Assigns. This Instrument shall inure to the benefit of and be
binding upon Grantor, Trustee and Agent and their respective heirs, executors, legal
representatives, successors and assigns. Whenever a reference is made in this Instrument to
Grantor, Trustee or Agent such reference shall be deemed to include a reference to the heirs,
executors, legal representatives, successors and assigns of Grantor or Agent.

     28.2 Terminology. All personal pronouns used in this Instrument whether used in the
masculine, feminine or neuter gender, shall include all other genders; the singular shall include
the plural, and vice versa. Titles and Articles are for convenience only and neither limit nor
amplify the provisions of this Instrument itself, and all references herein to Articles, Sections
or subsections thereof, shall refer to the corresponding Articles, Sections or subsections thereof,
of this Instrument unless specific reference is made to such Articles, Sections or subsections
thereof of another document or instrument.

22

 

     28.3 Severability. If any provision of this Instrument or the application thereof to
any person or circumstance shall be invalid or unenforceable to any extent, the remainder of this
Instrument and the application of such provisions to other persons or circumstances shall not be
affected thereby and shall be enforced to the greatest extent permitted by law.

     28.4 Applicable Law. This Instrument will be governed by the substantive laws of the
District of Columbia, without giving effect to its principles of choice of law or conflicts of law
(except with respect to choice of law or conflicts of law provisions of its Uniform Commercial
Code), and the laws of the United States applicable to transactions in District of Columbia.
Should any obligation or remedy under this Instrument be invalid or unenforceable pursuant to the
laws provided herein to govern, the laws of any other state referred to herein or of another state
whose laws can validate and apply thereto shall govern.

     28.5 Notices. Except as otherwise provided herein, each notice, demand, election or
request provided for or permitted to be given pursuant to this Agreement (hereinafter in this
Section 3.05 referred to as “Notice”), but specifically excluding to the maximum extent permitted
by law any notices of the institution or commencement of foreclosure proceedings, must be in
writing and shall be deemed to have been properly given or served by personal delivery or by
sending same by overnight courier or by depositing same in the United States Mail, postpaid and
registered or certified, return receipt requested, or as expressly permitted herein, by telegraph,
telecopy, telefax or telex, and addressed as follows:

     If to Grantor:

Republic 20th Street LLC

c/o Republic Property Limited Partnership

1280 Maryland Avenue, S.W.

Suite 280

Washington, D.C. 20024

Attention: Gary R. Siegel

Telecopy Number: (202) 863-4049

     And a copy to:

Glazer Winston Honigman Ellick

5301 Wisconsin Avenue, N.W.

Suite 740

Washington, D.C. 20015

Attention: Lori J. Honigman, Esq.

Telecopy Number: (202) 537-5505

     If to Agent:

KeyBank National Association, as Agent

127 Public Square

8th Floor

OH-01-27-0839

Cleveland, Ohio 44114-1306

Attn: Michael P. Szuba

Telecopy Number: (216) 689-4997

23

 

     And a copy to:

McKenna Long & Aldridge LLP

Suite 5300

303 Peachtree Street, N.E.

Atlanta, Georgia 30308

Attention: William F. Timmons, Esq.

Telecopy Number: (404) 527-4198

     If to Trustee:

Lawyers Title Realty Services, Inc.

c/o LandAmerica Commercial Services

1015 15th Street, N.W., Suite 300

Washington, DC 20005

Each Notice shall be effective upon being personally delivered or upon being sent by overnight
courier or upon being deposited in the United States Mail as aforesaid, or if transmitted by
telegraph, telecopy, telefax or telex is permitted, upon being sent and confirmation of receipt.
The time period in which a response to such Notice must be given or any action taken with respect
thereto (if any), however, shall commence to run from the date of receipt if personally delivered
or sent by overnight courier, or if so deposited in the United States Mail, the earlier of three
(3) Business Days following such deposit or the date of receipt as disclosed on the return receipt.
Rejection or other refusal to accept or the inability to deliver because of changed address for
which no notice was given shall be deemed to be receipt of the Notice sent. By giving at least
fifteen (15) days prior Notice thereof, Grantor, Agent and Trustee shall have the right from time
to time and at any time during the term of this Instrument to change their respective addresses and
each shall have the right to specify as its address any other address within the United States of
America.

     28.6 Conflict with Loan Agreement Provisions. Grantor hereby acknowledges and agrees
that, in the event of any conflict between the terms hereof and the terms of the Loan Agreement,
the terms of the Loan Agreement shall control.

     28.7 Assignment. This Instrument is assignable by Agent, and any assignment hereof by
Agent shall operate to vest in the assignee all rights and powers herein conferred upon and granted
to Agent.

     28.8 Time of the Essence. Time is of the essence with respect to each and every
covenant, agreement and obligation of Grantor under this Instrument, and any and all other
instruments now or hereafter evidencing, securing or otherwise relating to the Secured Obligations.

     28.9 Site Visits, Observation and Testing. Agent and its agents and representatives
shall have the right at any reasonable time to enter and visit the Property for the purpose of
performing appraisals, observing the Property, taking and removing soil or groundwater samples, and
conducting tests on any part of the Property. Agent has no duty, however, to visit or observe the
Property or to conduct tests, and no site visit, observation or testing by Agent, its agents or
representatives shall impose any liability on any of Agent, its agents or representatives. In no
event shall any site visit, observation or testing by Agent, its agents or representatives be a
representation that Hazardous Material are or are not present in, on or under the Property, or that
there has been or shall be compliance with any law, regulation or ordinance pertaining to Hazardous
Material or any other applicable governmental law. Neither Grantor nor any other party is entitled
to rely on any site visit, observation or testing by any of Agent, its agents or representatives.
Neither Agent, its agents or representatives owe any duty of care to protect Grantor or any other
party against, or to inform Grantor or any other party of, any Hazardous Material or any other
adverse condition affecting the Property. Agent shall give Grantor reasonable notice before
entering the Property. Agent shall make reasonable efforts to avoid interfering with Grantor’s use
of the Property in exercising any rights provided in this Section 3.09.

     28.10 Commercial Loan. Grantor hereby represents and warrants that it is a business
or commercial organization and further represents and warrants that the Loan was made and
transacted solely for the purpose of carrying on or acquiring a business, professional, commercial
or investment activity and that the Loan is not subject

24

 

to the limitations on maximum allowable interest rates under Title 28, Chapter 33 of the D. C.
Code governing interest and usury.

     28.11 Fixture Filing. This instrument constitutes a financing statement filed as a
fixture filing under Article 9 of the UCC, covering any Project which now is or later may become
fixtures attached the Land or Improvements. For this purpose, the respective addresses of Grantor,
as debtor and Agent and Trustee, a s secured parties, a re as set forth in the preambles of this
Instrument.

ARTICLE 29

     29.1 Any Trustee May Act; Substitution Permitted. If the Trustee at any time consists
of more than one Person, the powers of the Trustee may be exercised by either Trustee or by any
successor Trustee with the same effect as if exercised jointly by both of them. Agent has the
power and shall be entitled, at any time and from time to time, to remove the Trustee or any
successor trustee and to appoint another trustee in the place of the Trustee or any successor
trustee, by an instrument recorded in the Office of the Register of Deeds of the District of
Columbia. The recorded instrument shall be conclusive proof of the proper substitution and
appointment of the successor trustee without the necessity of any conveyance from the predecessor
trustee.

     29.2 Compensation and Expenses. Grantor shall pay the Trustee just compensation for
any and all services performed and all Trustee’s expenses, charges, reasonable attorneys’ fees and
other obligations incurred in the administration and execution of the trust hereby created and the
performance of Trustee’s duties and powers hereunder, which compensation, expenses, fees and
disbursements shall constitute a part of the Secured Obligations.

     29.3 Performance of Duties; Liability. Trustee shall perform and fulfill faithfully
Trustee’s obligations hereunder but shall be under no duty to act until Trustee receives notice of
the occurrence of an Event of Default from Agent and arrangements have been made which are
satisfactory to Trustee for the indemnification to which Trustee is entitled, the payment of
Trustee’s compensation and the reimbursement of any expenses Trustee may incur in the performance
of Trustee’s duties. Trustee shall have no liability for Trustee’s acts unless Trustee is guilty
of willful misconduct or gross negligence.

25

 

     IN WITNESS WHEREOF, Grantor has executed this Instrument as of the day and year first above
written.

	 	 	 	 	 
	 	REPUBLIC 20TH STREET LLC, a Delaware limited liability company

 	 
	 	By:  	/s/ Gary R. Siegel
 	 
	 	 	Name:  	Gary R. Siegel 	 
	 	 	Title:  	Chief Operating Officer 	 
	 

 

 

	 	 
	STATE OF MARYLAND                      
	)
	 
	)
	COUNTY OF PRINCE GEORGE )
	

          On February 15, 2007 before me, Leslie Bridges
               , Notary Public, personally appeared Gary R. Siegel
              , personally known to me to be the person(s) whose name(s) is/are subscribed to
the within instrument and acknowledged to me that he/she/they executed the same in his/her/their
capacity as Chief Operating Officer of Republic 20th Street LLC, a Delaware
limited liability company, and that by his/her/their signature(s) on the instrument the person(s),
or the entity upon behalf of which the person(s) acted, executed the instrument.

          WITNESS my hand and official seal.

/s/
Leslie Bridges                    
                             

Notary Public

My commission expires:  5/07/2007          

 

 

EXHIBIT “A”

EXHIBIT “A” — PAGE 1

 

 

EXHIBIT “B”

Permitted Encumbrances

     Permitted encumbrances are such matters as are shown on Schedule B, Part I to the Pro-Forma
Title Insurance Policy No. 07-001041 issued by Commonwealth Land Title Insurance Company to the
Agent in connection with this Instrument and attached to that certain escrow instruction letter
dated on or about the date hereof between LandAmerica Commercial Services and Agent.

EXHIBIT “B” — PAGE 1

 

 

EXHIBIT “C”

Schedule 1

(Description of “Debtor” and “Secured Party”)

	 	A.	 	Debtor:

	 	1.	 	REPUBLIC 20TH STREET LLC, a Delaware limited liability company organized under the laws

of the State of Delaware. Debtor has been using or operating under said name and identity or

corporate structure without change since January 17, 2007.
	 
	 	 	 	Names and Tradenames used within last five years: None.
	 
	 	 	 	Location of all chief executive offices over last five years:
1280 Maryland Avenue, S.W., Washington, DC 20024.
	 
	 	 	 	Organizational Number: 4286545
	 
	 	 	 	Federal Tax Identification Number: 20-3241959 (RPLP’s No.)

	 	B.	 	Secured Party:

	 	 	 	KEYBANK NATIONAL ASSOCIATION, a national banking association, as Agent.

Schedule 2

(Notice Mailing Addresses of “Debtor” and “Secured Party”)

	 	A.	 	The mailing address of Debtor is:
	 
	 	 	 	c/o Republic Property Limited Partnership

13861 Sunrise Valley Drive

Herndon, Virginia 20171
	 
	 	B.	 	The mailing address of Secured Party is:
	 
	 	 	 	KeyBank National Association, as Agent

127 Public Square

8th Floor

OH-01-27-0839

Cleveland, Ohio 44114-1306

M-1

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00119-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00119-of-00352.parquet"}]]