Document:

alamoex102.htm

 

Exhibit 10.2

 

NEITHER THE ISSUANCE AND SALE OF THE SECURITIES REPRESENTED BY THIS CERTIFICATE NOR THE SECURITIES INTO WHICH THESE SECURITIES ARE EXERCISABLE HAVE BEEN REGISTERED UNDER THE SECURITIES ACT OF 1933, AS AMENDED, OR APPLICABLE STATE SECURITIES LAWS.  THE SECURITIES MAY NOT BE OFFERED FOR SALE, SOLD, TRANSFERRED OR ASSIGNED (I) IN THE ABSENCE OF (A) AN EFFECTIVE REGISTRATION STATEMENT FOR THE SECURITIES UNDER THE SECURITIES ACT OF 1933, AS AMENDED, OR (B) AN OPINION OF COUNSEL (WHICH COUNSEL SHALL BE SELECTED BY THE HOLDER), IN A GENERALLY ACCEPTABLE FORM, THAT REGISTRATION IS NOT REQUIRED UNDER SAID ACT OR (II) UNLESS SOLD PURSUANT TO RULE 144 OR RULE 144A UNDER SAID ACT.  NOTWITHSTANDING THE FOREGOING, THE SECURITIES MAY BE PLEDGED IN CONNECTION WITH A BONA FIDE MARGIN ACCOUNT OR OTHER LOAN OR FINANCING ARRANGEMENT SECURED BY THE SECURITIES.

 

	  	
Right to Purchase 75,000 shares of Common Stock of Alamo Energy Corp. (subject to adjustment as provided herein)

 

COMMON STOCK PURCHASE WARRANT

 

	
 No. 2010-011                               

	
 Issue Date:  December 15, 2010

 

 

ALAMO ENERGY CORP., a corporation organized under the laws of the State of Nevada (the “Company”), hereby certifies that, for value received, _______________________, or its assigns (the “Holder”), is entitled, subject to the terms set forth below, to purchase from the Company at any time commencing on the Issue Date until 5:00 p.m., P.T. on the fifth anniversary of the Issue Date (the “Expiration Date”), up to 75,000 fully paid and nonassessable shares of Common Stock at a per share purchase price of $1.00.  The aforedescribed purchase price per share, as adjusted from time to time as herein provided, is referred to herein as the “Purchase Price.”  The number and character of such shares of Common Stock and the Purchase Price are subject to adjustment as provided herein.  The Company may reduce the Purchase Price for some or all of the Warrants, temporarily or permanently.  Capitalized terms used and not otherwise defined herein shall have the meanings set forth in that certain Senior Secured Convertible Promissory Note (the “Promissory Note”), dated as of December 15, 2010, entered into by the Company and the Holder in connection with the Holder’s purchase of certain debt securities of the Company.

 

As used herein the following terms, unless the context otherwise requires, have the following respective meanings:

 

(a)           The term “Company” shall include Alamo Energy Corp., and any corporation that shall succeed or assume the obligations of Alamo Energy Corp. hereunder.

 

(b)           The term “Common Stock” includes (a) the Company’s common stock, $.001 par value per share, as authorized on the date of the Promissory Note, and (b) any other securities into which or for which any of the securities described in (a) may be converted or exchanged pursuant to a plan of recapitalization, reorganization, merger, sale of assets or otherwise.

 

(c)           The term “Other Securities” refers to any stock (other than Common Stock) and other securities of the Company or any other person (corporate or otherwise) that the holder of the Warrant at any time shall be entitled to receive, or shall have received, on the exercise of the Warrant, in lieu of or in addition to Common Stock, or which at any time shall be issuable or shall have been issued in exchange for or in replacement of Common Stock or Other Securities pursuant to Section 4 or otherwise.

 

(d)           The term “Warrant Shares” shall mean the Common Stock issuable upon exercise of this Warrant.

 

 

 

  

1

  

 

1.           Exercise of Warrant.

 

1.1.           Number of Shares Issuable upon Exercise.  From and after the Issue Date through and including the Expiration Date, the Holder hereof shall be entitled to receive, upon exercise of this Warrant in whole in accordance with the terms of subsection 1.2 or upon exercise of this Warrant in part in accordance with subsection 1.3, shares of Common Stock of the Company, subject to adjustment pursuant to Section 4.

 

1.2.           Full Exercise.  This Warrant may be exercised in full by the Holder hereof by delivery of an original or facsimile copy of the form of subscription attached as Exhibit A hereto (the “Subscription Form”) duly executed by such Holder and delivery within two days thereafter of payment, in cash, wire transfer or by certified or official bank check payable to the order of the Company, in the amount obtained by multiplying the number of shares of Common Stock for which this Warrant is then exercisable by the Purchase Price then in effect.  The original Warrant is not required to be surrendered to the Company until it has been fully exercised.

 

1.3.           Partial Exercise.  This Warrant may be exercised in part (but not for a fractional share) by delivery of a Subscription Form in the manner and at the place provided in subsection 1.2 except that the amount payable by the Holder on such partial exercise shall be the amount obtained by multiplying (a) the number of whole shares of Common Stock designated by the Holder in the Subscription Form by (b) the Purchase Price then in effect.  On any such partial exercise provided the Holder has surrendered the original Warrant, the Company, at its expense, will forthwith issue and deliver to or upon the order of the Holder hereof a new Warrant of like tenor, in the name of the Holder hereof or as such Holder (upon payment by such Holder of any applicable transfer taxes) may request, the whole number of shares of Common Stock for which such Warrant may still be exercised.

 

1.4.           Fair Market Value.  Fair Market Value of a share of Common Stock as of a particular date (the “Determination Date”) shall mean:

 

(a)           If the Company’s Common Stock is listed, traded, or quoted on the NASDAQ Global Market, NASDAQ Global Select Market, the NASDAQ Capital Market, the New York Stock Exchange, the American Stock Exchange, LLC, the OTC Bulletin Board, or the Pink OTC Markets Inc., then the average of the closing or last sale prices, respectively, reported for the ten trading days immediately preceding the Determination Date;

 

(b)           If the Company’s Common Stock is not listed, traded, or quoted on the NASDAQ Global Market, NASDAQ Global Select Market, the NASDAQ Capital Market, the New York Stock Exchange, the American Stock Exchange, LLC, the OTC Bulletin Board, or the Pink OTC Markets Inc., but is traded in the over-the-counter market, then the average of the closing bid and ask prices reported for the ten trading days immediately preceding the Determination Date;

 

(c)           Except as provided in clause (d) below and Section 3.1, if the Company’s Common Stock is not so publicly listed, traded or quoted, then as the Holder and the Company agree, or in the absence of such an agreement, by arbitration in accordance with the rules then standing of the American Arbitration Association, before a single arbitrator to be chosen from a panel of persons qualified by education and training to pass on the matter to be decided with such arbitration to be conducted in New York City, New York; or

 

(d)           If the Determination Date is the date of a liquidation, dissolution or winding-up, or any event deemed to be a liquidation, dissolution, or winding-up pursuant to the Company’s charter, then all amounts to be payable per share to holders of the Common Stock pursuant to the charter in the event of such liquidation, dissolution or winding up, plus all other amounts to be payable per share in respect of the Common Stock in liquidation under the charter, assuming for the purposes of this clause (d) that all of the shares of Common Stock then issuable upon exercise of all of the Warrants are outstanding at the Determination Date.

 

 

 

  

2

  

 

1.5.           Company Acknowledgment.  The Company will, at the time of the exercise of the Warrant, upon the request of the Holder hereof, acknowledge in writing its continuing obligation to afford to such Holder any rights to which such Holder shall continue to be entitled after such exercise in accordance with the provisions of this Warrant.  If the Holder shall fail to make any such request, such failure shall not affect the continuing obligation of the Company to afford to such Holder any such rights.

 

1.6.           Trustee for Warrant Holders.  In the event that a bank or trust company shall have been appointed as trustee for the Holder of the Warrants pursuant to Subsection 3.2, such bank or trust company shall have all the powers and duties of a warrant agent (as hereinafter described) and shall accept, in its own name for the account of the Company or such successor person as may be entitled thereto, all amounts otherwise payable to the Company or such successor, as the case may be, on exercise of this Warrant pursuant to this Section 1.

 

1.7           Delivery of Stock Certificates, etc. on Exercise.  The Company agrees that the Warrant Shares shall be deemed to be issued to the Holder hereof as the record owner of such shares as of the close of business on the date on which delivery of a Subscription Form shall have occurred and payment made for such shares as aforesaid.  As soon as practicable after the exercise of this Warrant in full or in part, and in any event within ten (10) business days thereafter (“Warrant Share Delivery Date”), the Company at its expense (including the payment by it of any applicable issue taxes) will cause to be issued in the name of and delivered to the Holder hereof, or as such Holder (upon payment by such Holder of any applicable transfer taxes) may direct in compliance with applicable securities laws, a certificate or certificates for the number of duly and validly issued, fully paid and non-assessable shares of Common Stock (or Other Securities) to which such Holder shall be entitled on such exercise, plus, in lieu of any fractional share to which such Holder would otherwise be entitled, cash equal to such fraction multiplied by the then Fair Market Value of one full share of Common Stock, together with any other stock or other securities and property (including cash, where applicable) to which such Holder is entitled upon such exercise pursuant to Section 1 or otherwise.  The Company understands that a delay in the delivery of the Warrant Shares after the Warrant Share Delivery Date could result in economic loss to the Holder.  As compensation to the Holder for such loss, the Company agrees to pay (as liquidated damages and not as a penalty) to the Holder for late issuance of Warrant Shares upon exercise of this Warrant the proportionate amount of $100 per business day after the Warrant Share Delivery Date for each $10,000 of Purchase Price of Warrant Shares for which this Warrant is exercised which are not timely delivered.  The Company shall pay any payments incurred under this Section in immediately available funds upon demand.  Furthermore, in addition to any other remedies which may be available to the Holder, in the event that the Company fails for any reason to effect delivery of the Warrant Shares by the Warrant Share Delivery Date, the Holder may revoke all or part of the relevant Warrant exercise by delivery of a notice to such effect to the Company, whereupon the Company and the Holder shall each be restored to their respective positions immediately prior to the exercise of the relevant portion of this Warrant, except that the liquidated damages described above shall be payable through the date notice of revocation or rescission is given to the Company.

 

1.8           Buy-In.  In addition to any other rights available to the Holder, if the Company fails to deliver to a Holder the Warrant Shares as required pursuant to this Warrant within seven (7) business days after the Warrant Share Delivery Date and the Holder or a broker on the Holder’s behalf purchases (in an open market transaction or otherwise) shares of common stock to deliver in satisfaction of a sale by such Holder of the Warrant Shares which the Holder was entitled to receive from the Company (a “Buy-In”), then the Company shall pay in cash to the Holder (in addition to any remedies available to or elected by the Holder) the amount by which (A) the Holder’s total purchase price (including brokerage commissions, if any) for the shares of common stock so purchased exceeds (B) the aggregate Purchase Price of the Warrant Shares required to have been delivered, together with interest thereon at a rate of 15% per annum, accruing until such amount and any accrued interest thereon is paid in full (which amount shall be paid as liquidated damages and not as a penalty).  For example, if a Holder purchases shares of Common Stock having a total purchase price of $11,000 to cover a Buy-In with respect to $10,000 of Purchase Price of Warrant Shares to have been received upon exercise of this Warrant, the Company shall be required to pay the Holder $1,000, plus interest.  The Holder shall provide the Company written notice indicating the amounts payable to the Holder in respect of the Buy-In.

 

 

 

  

3

  

 

2.           Cashless Exercise.

 

(a)           If a registration statement (“Registration Statement”) is effective for the public unrestricted resale of all of the Warrant Shares issuable upon exercise of this Warrant, this Warrant may be exercised in whole or in part for cash only as set forth in Section 1 above.  If such Registration Statement is not available, payment upon exercise may be made at the option of the Holder either in (i) cash, wire transfer or by certified or official bank check payable to the order of the Company equal to the applicable aggregate Purchase Price, (ii) by delivery of Common Stock issuable upon exercise of the Warrants in accordance with Section (b) below or (iii) by a combination of any of the foregoing methods, for the number of Common Stock specified in such form (as such exercise number shall be adjusted to reflect any adjustment in the total number of shares of Common Stock issuable to the holder per the terms of this Warrant) and the holder shall thereupon be entitled to receive the number of duly authorized, validly issued, fully-paid and non-assessable shares of Common Stock (or Other Securities) determined as provided herein.

 

(b)           Subject to the provisions herein to the contrary, if the Fair Market Value of one share of Common Stock is greater than the Purchase Price (at the date of calculation as set forth below), in lieu of exercising this Warrant for cash, the holder may elect to receive shares equal to the value (as determined below) of this Warrant (or the portion thereof being cancelled) by surrender of this Warrant at the principal office of the Company together with the properly endorsed Subscription Form in which event the Company shall issue to the holder a number of shares of Common Stock computed using the following formula:

 

X=Y (A-B)

                A

 

	
  Where

	
X=

	
the number of shares of Common Stock to be issued to the holder

 

	  	
Y=

	
the number of shares of Common Stock purchasable under the Warrant or, if only a portion of the Warrant is being exercised, the portion of the Warrant being exercised (at the date of such calculation)

 

	  	
A=

	
the average of the closing sale prices of the Common Stock for the ten (10) Trading Days immediately prior to (but not including) the Exercise Date, (or if no such closing prices are available, then the Fair Market Value)

 

	  	
B=

	
Purchase Price (as adjusted to the date of such calculation)

 

For purposes of Rule 144 promulgated under the 1933 Act, it is intended, understood, and acknowledged that the Warrant Shares issued in a cashless exercise transaction shall be deemed to have been acquired by the Holder, and the holding period for the Warrant Shares shall be deemed to have commenced, on the date this Warrant was originally issued pursuant to the Promissory Note.

 

 

 

  

4

  

 

3.           Adjustment for Reorganization, Consolidation, Merger, etc.

 

3.1.           Fundamental Transaction.  If, at any time while this Warrant is outstanding, (A) the Company effects any merger or consolidation of the Company with or into another entity, (B) the Company effects any sale of all or substantially all of its assets in one or a series of related transactions, (C) any tender offer or exchange offer (whether by the Company or another entity) is completed pursuant to which holders of Common Stock are permitted to tender or exchange their shares for other securities, cash or property, (D) the Company consummates a stock purchase agreement or other business combination (including, without limitation, a reorganization, recapitalization, spin-off or scheme of arrangement) with one or more persons or entities whereby such other persons or entities acquire more than the 50% of the outstanding shares of Common Stock (not including any shares of Common Stock held by such other persons or entities making or party to, or associated or affiliated with the other persons or entities making or party to, such stock purchase agreement or other business combination), (E) any “person” or “group” (as these terms are used for purposes of Sections 13(d) and 14(d) of the 1934 Act) is or shall become the “beneficial owner” (as defined in Rule 13d-3 under the 1934 Act), directly or indirectly, of 50% of the aggregate Common Stock of the Company, or (F) the Company effects any reclassification of the Common Stock or any compulsory share exchange pursuant to which the Common Stock is effectively converted into or exchanged for other securities, cash or property (in any such case, a “Fundamental Transaction”), then, upon any subsequent exercise of this Warrant, the Holder shall have the right to receive, for each Warrant Share that would have been issuable upon such exercise immediately prior to the occurrence of such Fundamental Transaction, at the option of the Holder, (a) upon exercise of this Warrant, the number of shares of Common Stock of the successor or acquiring corporation or of the Company, if it is the surviving corporation, and any additional consideration (the “Alternate Consideration”) receivable upon or as a result of such reorganization, reclassification, merger, consolidation or disposition of assets by a Holder of the number of shares of Common Stock for which this Warrant is exercisable immediately prior to such event or (b) if the Company is acquired in (1) a transaction where the consideration paid to the holders of the Common Stock consists solely of cash, (2) a “Rule 13e-3 transaction” as defined in Rule 13e-3 under the 1934 Act, or (3) a transaction involving a person or entity not traded on a national securities exchange, the Nasdaq Global Select Market, the Nasdaq Global Market, or the Nasdaq Capital Market, cash equal to the Black-Scholes Value.  For purposes of any such exercise, the determination of the Purchase Price shall be appropriately adjusted to apply to such Alternate Consideration based on the amount of Alternate Consideration issuable in respect of one share of Common Stock in such Fundamental Transaction, and the Company shall apportion the Purchase Price among the Alternate Consideration in a reasonable manner reflecting the relative value of any different components of the Alternate Consideration.  If holders of Common Stock are given any choice as to the securities, cash, or property to be received in a Fundamental Transaction, then the Holder shall be given the same choice as to the Alternate Consideration it receives upon any exercise of this Warrant following such Fundamental Transaction.  To the extent necessary to effectuate the foregoing provisions, any successor to the Company or surviving entity in such Fundamental Transaction shall issue to the Holder a new warrant consistent with the foregoing provisions and evidencing the Holder’s right to exercise such warrant into Alternate Consideration.  The terms of any agreement pursuant to which a Fundamental Transaction is effected shall include terms requiring any such successor or surviving entity to comply with the provisions of this Section 3.1 and ensuring that this Warrant (or any such replacement security) will be similarly adjusted upon any subsequent transaction analogous to a Fundamental Transaction.  “Black-Scholes Value” shall be determined in accordance with the Black-Scholes Option Pricing Model obtained from the “OV” function on Bloomberg L.P. using (i) a price per share of Common Stock equal to the VWAP of the Common Stock for the Trading Day immediately preceding the date of consummation of the applicable Fundamental Transaction, (ii) a risk-free interest rate corresponding to the U.S. Treasury rate for a period equal to the remaining term of this Warrant as of the date of such request, and (iii) an expected volatility equal to the 100-day volatility obtained from the HVT function on Bloomberg L.P. determined as of the Trading Day immediately following the public announcement of the applicable Fundamental Transaction.

 

 

 

  

5

  

 

3.2.           Dissolution.  In the event of any dissolution of the Company following the transfer of all or substantially all of its properties or assets, the Company, prior to such dissolution, shall at its expense, deliver or cause to be delivered the stock and other securities and property (including cash, where applicable) receivable by the Holder of the Warrants after the effective date of such dissolution pursuant to this Section 3 to a bank or trust company (a “Trustee”) having its principal office in New York, NY, as trustee for the Holder of the Warrants.  Such property shall be delivered only upon payment of the Warrant exercise price.

 

3.3.           Continuation of Terms.  Upon any reorganization, consolidation, merger or transfer (and any dissolution following any transfer) referred to in this Section 3, this Warrant shall continue in full force and effect and the terms hereof shall be applicable to the Other Securities and property receivable on the exercise of this Warrant after the consummation of such reorganization, consolidation or merger or the effective date of dissolution following any such transfer, as the case may be, and shall be binding upon the issuer of any Other Securities, including, in the case of any such transfer, the person acquiring all or substantially all of the properties or assets of the Company, whether or not such person shall have expressly assumed the terms of this Warrant as provided in Section 4.  In the event this Warrant does not continue in full force and effect after the consummation of the transaction described in this Section 3, then only in such event will the Company’s securities and property (including cash, where applicable) receivable by the Holder of the Warrants be delivered to the Trustee as contemplated by Section 3.2.

 

4.           Extraordinary Events Regarding Common Stock.  In the event that the Company shall (a) issue additional shares of the Common Stock as a dividend or other distribution on outstanding Common Stock, (b) subdivide its outstanding shares of Common Stock, or (c) combine its outstanding shares of the Common Stock into a smaller number of shares of the Common Stock, then, in each such event, the Purchase Price shall, simultaneously with the happening of such event, be adjusted by multiplying the then Purchase Price by a fraction, the numerator of which shall be the number of shares of Common Stock outstanding immediately prior to such event and the denominator of which shall be the number of shares of Common Stock outstanding immediately after such event, and the product so obtained shall thereafter be the Purchase Price then in effect. The Purchase Price, as so adjusted, shall be readjusted in the same manner upon the happening of any successive event or events described herein in this Section 4.  The number of shares of Common Stock that the Holder of this Warrant shall thereafter, on the exercise hereof, be entitled to receive shall be adjusted to a number determined by multiplying the number of shares of Common Stock that would otherwise (but for the provisions of this Section 4) be issuable on such exercise by a fraction of which (a) the numerator is the Purchase Price that would otherwise (but for the provisions of this Section 4) be in effect, and (b) the denominator is the Purchase Price in effect on the date of such exercise.

 

5.           Certificate as to Adjustments.  In each case of any adjustment or readjustment in the shares of Common Stock (or Other Securities) issuable on the exercise of the Warrants, the Company at its expense will promptly cause its Chief Financial Officer or other appropriate designee to compute such adjustment or readjustment in accordance with the terms of the Warrant and prepare a certificate setting forth such adjustment or readjustment and showing in detail the facts upon which such adjustment or readjustment is based, including a statement of (a) the consideration received or receivable by the Company for any additional shares of Common Stock (or Other Securities) issued or sold or deemed to have been issued or sold, (b) the number of shares of Common Stock (or Other Securities) outstanding or deemed to be outstanding, and (c) the Purchase Price and the number of shares of Common Stock to be received upon exercise of this Warrant, in effect immediately prior to such adjustment or readjustment and as adjusted or readjusted as provided in this Warrant. The Company will forthwith mail a copy of each such certificate to the Holder of the Warrant and any Warrant Agent of the Company (appointed pursuant to Section 12 hereof).

 

 

 

  

6

  

 

6.           Reservation of Stock, etc. Issuable on Exercise of Warrant; Financial Statements.  The Company will at all times reserve and keep available, solely for issuance and delivery on the exercise of the Warrants, all shares of Common Stock (or Other Securities) from time to time issuable on the exercise of the Warrant.  This Warrant entitles the Holder hereof to receive copies of all financial and other information distributed or required to be distributed to the holders of the Company’s Common Stock.

 

7.           Assignment; Exchange of Warrant.  Subject to compliance with applicable securities laws, this Warrant, and the rights evidenced hereby, may be transferred by any registered holder hereof (a “Transferor”). On the surrender for exchange of this Warrant, with the Transferor’s endorsement in the form of Exhibit B attached hereto (the “Transferor Endorsement Form”) and together with an opinion of counsel reasonably satisfactory to the Company that the transfer of this Warrant will be in compliance with applicable securities laws, the Company will issue and deliver to or on the order of the Transferor thereof a new Warrant or Warrants of like tenor, in the name of the Transferor and/or the transferee(s) specified in such Transferor Endorsement Form (each a “Transferee”), calling in the aggregate on the face or faces thereof for the number of shares of Common Stock called for on the face or faces of the Warrant so surrendered by the Transferor.

 

8.           Replacement of Warrant.  On receipt of evidence reasonably satisfactory to the Company of the loss, theft, destruction or mutilation of this Warrant and, in the case of any such loss, theft or destruction of this Warrant, on delivery of an indemnity agreement or security reasonably satisfactory in form and amount to the Company or, in the case of any such mutilation, on surrender and cancellation of this Warrant, the Company at its expense, twice only, will execute and deliver, in lieu thereof, a new Warrant of like tenor.

 

9.           Reserved.

 

10.           Maximum Exercise.  The Holder shall not be entitled to exercise this Warrant on an exercise date in connection with that number of Common Stock which would be in excess of the sum of (i) the number of Common Stock beneficially owned by the Holder and its affiliates on an exercise date, and (ii) the number of shares of Common Stock issuable upon the exercise of this Warrant with respect to which the determination of this limitation is being made on an exercise date, which would result in beneficial ownership by the Holder and its affiliates of more than 4.99% of the outstanding Common Stock on such date.  For the purposes of the immediately preceding sentence, beneficial ownership shall be determined in accordance with Section 13(d) of the Securities Exchange Act of 1934, as amended, and Regulation 13d-3 thereunder.  Subject to the foregoing, the Holder shall not be limited to aggregate exercises which would result in the issuance of more than 4.99%.  The restriction described in this paragraph may be waived, in whole or in part, upon sixty-one (61) days prior notice from the Holder to the Company to increase such percentage to up to 9.99%.  The Holder may allocate which of the equity of the Company deemed beneficially owned by the Subscriber shall be included in the 4.99% amount described above and which shall be allocated to the excess above 4.99%.

 

11.           Reserved.

 

12.           Warrant Agent.  The Company may, by written notice to the Holder of the Warrant, appoint an agent (a “Warrant Agent”) for the purpose of issuing Common Stock (or Other Securities) on the exercise of this Warrant pursuant to Section 1, exchanging this Warrant pursuant to Section 7, and replacing this Warrant pursuant to Section 8, or any of the foregoing, and thereafter any such issuance, exchange or replacement, as the case may be, shall be made at such office by such Warrant Agent.

 

13.           Transfer on the Company’s Books.  Until this Warrant is transferred on the books of the Company, the Company may treat the registered holder hereof as the absolute owner hereof for all purposes, notwithstanding any notice to the contrary.

 

 

 

  

7

  

 

14.           Notices.  All notices, demands, requests, consents, approvals, and other communications required or permitted hereunder shall be in writing and, unless otherwise specified herein, shall be (i) personally served, (ii) deposited in the mail, registered or certified, return receipt requested, postage prepaid, (iii) delivered by reputable air courier service with charges prepaid, or (iv) transmitted by hand delivery, telegram, or facsimile, addressed as set forth below or to such other address as such party shall have specified most recently by written notice.  Any notice or other communication required or permitted to be given hereunder shall be deemed effective (a) upon hand delivery or delivery by facsimile, with accurate confirmation generated by the transmitting facsimile machine, at the address or number designated below (if delivered on a business day during normal business hours where such notice is to be received), or the first business day following such delivery (if delivered other than on a business day during normal business hours where such notice is to be received) or (b) on the second business day following the date of mailing by express courier service, fully prepaid, addressed to such address, or upon actual receipt of such mailing, whichever shall first occur.  The addresses for such communications shall be:  if to the Company, to:  Alamo Energy Corp., 10497 Town and Country Way, Suite 310, Houston, TX 77024,  Attn: Allan Millmaker, President, with a copy by facsimile only to:  _____________________, facsimile:  _______________, and (ii) if to the Holder, __________________________________.

 

 

15.           Law Governing This Warrant.  This Warrant shall be governed by and construed in accordance with the laws of the State of Nevada without regard to principles of conflicts of laws.  Any action brought by either party against the other concerning the transactions contemplated by this Warrant shall be brought only in the state courts of Nevada or in the federal courts located in the State of Nevada.  The parties to this Warrant hereby irrevocably waive any objection to jurisdiction and venue of any action instituted hereunder and shall not assert any defense based on lack of jurisdiction or venue or based upon forum non conveniens.  The Company and Holder waive trial by jury.  The prevailing party shall be entitled to recover from the other party its reasonable attorney’s fees and costs.  In the event that any provision of this Warrant or any other agreement delivered in connection herewith is invalid or unenforceable under any applicable statute or rule of law, then such provision shall be deemed inoperative to the extent that it may conflict therewith and shall be deemed modified to conform to such statute or rule of law.  Any such provision which may prove invalid or unenforceable under any law shall not affect the validity or enforceability of any other provision of any agreement.

 

 

[BALANCE OF PAGE INTENTIONALLY LEFT BLANK]

 

 

 

 

  

8

  

 

IN WITNESS WHEREOF, the Company has executed this Warrant as of the date first written above.

 

ALAMO ENERGY CORP.

 

       

 

	
 By:    

	
 /s/Philip Mann

	  
	  	
 Philip Mann, Chief Financial Officer

	  

 

 

 

 

 

  

9

  

 

Exhibit A

FORM OF SUBSCRIPTION

(to be signed only on exercise of Warrant)

TO:  ALAMO ENERGY CORP.

The undersigned, pursuant to the provisions set forth in the attached Warrant (No.____), hereby irrevocably elects to purchase (check applicable box):

[___]           ________ shares of the Common Stock covered by such Warrant; or

[___]           the maximum number of shares of Common Stock covered by such Warrant pursuant to the cashless exercise procedure set forth in Section 2.

The undersigned herewith makes payment of the full purchase price for such shares at the price per share provided for in such Warrant, which is $___________.  Such payment takes the form of (check applicable box or boxes):

[___]           $__________ in lawful money of the United States; and/or

[___]           the cancellation of such portion of the attached Warrant as is exercisable for a total of _______ shares of Common Stock (using a Fair Market Value of $_______ per share for purposes of this calculation); and/or

 

[___]           the cancellation of such number of shares of Common Stock as is necessary, in accordance with the formula set forth in Section 2, to exercise this Warrant with respect to the maximum number of shares of Common Stock purchasable pursuant to the cashless exercise procedure set forth in Section 2.

 

The undersigned requests that the certificates for such shares be issued in the name of, and delivered to _______________________________________________________________________ whose address is

 

The undersigned represents and warrants that all offers and sales by the undersigned of the securities issuable upon exercise of the within Warrant shall be made pursuant to registration of the Common Stock under the Securities Act of 1933, as amended (the “Securities Act”), or pursuant to an exemption from registration under the Securities Act.

 

	
 Dated: 

	  	  	  	  
	  	
(Signature must conform to name of holder as specified on the face of the Warrant)

	  
	  	  	  
	  	  	  
	  	  	  
	  	
  Address:

	  
	  	  	  

 

 

  

10

  

 

Exhibit B

 

FORM OF TRANSFEROR ENDORSEMENT

(To be signed only on transfer of Warrant)

For value received, the undersigned hereby sells, assigns, and transfers unto the person(s) named below under the heading “Transferees” the right represented by the within Warrant to purchase the percentage and number of shares of Common Stock of ALAMO ENERGY CORP., to which the within Warrant relates specified under the headings “Percentage Transferred” and “Number Transferred,” respectively, opposite the name(s) of such person(s) and appoints each such person Attorney to transfer its respective right on the books of ALAMO ENERGY CORP., with full power of substitution in the premises.

 

	
Transferees

	  	
Percentage Transferred

	  	
Number Transferred

	  	  	  	  	  
	  	  	  	  	  
	  	  	  	  	  

	
Dated:

	  	  	  	  
	  	
(Signature must conform to name of holder as specified on the face of the Warrant)

	  
	  	  	  
	
Signed in the presence of:

	  	  	  
	  	  	  	  
	
(Name)

	  	  
	  	
(Address)

	  
	  	  	  
	
ACCEPTED AND AGREED:

	  	  
	
TRANSFEREE]

	  	  
	  	
(Address)

	  
	  	  	  	  
	
(Name)

	  	  	  

 

11exhibit10_a.htm

 

 

 

 

EXHIBIT 10(a)

AGREEMENT

This Agreement (“Agreement”) is made and entered into by and between All American Building Systems, LLC, a limited liability company organized under the laws of the State of Indiana (“AABS”), and Caspar/Pope Joint Venture, a joint venture organized under the laws of the state of Wyoming, (“Contractor”) on this  7th day of September, 2010 (the “Effective Date”).

This Agreement consists of this cover and signature block plus:

Terms and Conditions of Sale

	
Exhibit A:

	
Identification of Project, Project Site and Work Sites

	
Exhibit B:

	
Scope of Work and Specifications

	
Exhibit C:

	
Purchase Price/Transfer of Ownership

	
Exhibit D:

	
Definitions Rider

	
Exhibit E:

	
Schedule of Work

	
Exhibit F:

	
Approved/Signed Plans

	
Exhibit G:

	
Change Order Form

	
Exhibit H:

	
Acceptance of Goods Form

	
Exhibit I:

	
Final Acceptance Form

	
Exhibit J:

	
Customer Service Manual

Signed as of the Effective Date

SIGNATURE BLOCK

All American Building Systems, LLC

By /s/ Greg Pope

Its Partner

 

SIGNATURE BLOCK

Casper/Pope Joint Venture

By /s/ Rick Bedell

Its President

 

TERMS AND CONDITIONS OF SALE

Contractor has entered into a General Contract with Casper College (“Owner” herein) for the construction of certain residence halls at Casper College.  Owner is the owner of a Community College Complex located at the site identified on Exhibit A (the "Project").  AABS has agreed to provide certain services and/or goods to Contractor to further the Project.  This Agreement and any exhibits or amendments hereto shall set forth the terms and conditions of the relationship between Contractor and AABS. All capitalized terms, unless otherwise defined in the text, shall have the meanings ascribed in the Definitions Rider, Exhibit D to this Agreement.

	
1.  

	
Purchase and Sale of Services and Goods.  AABS shall sell and Contractor shall purchase the modular units and/or services described in the Specifications, Plans, and Scope of Work pursuant to the Exhibits attached hereto.  Through this Agreement, AABS is selling modular units and services associated with the delivery, set, and interior carpentry finish of modular units.  AABS is specifically not selling a final building.  Except as provided for in this Agreement, AABS is not entitled to payment for the design work, mechanical work, and other forms of work necessary to transform the modular units into a finished building product, and is not responsible for completing the same.

	
2.  

	
Price and Payment Terms.  The Contract Price for the goods and/or services to be provided by AABS hereunder is set forth on Exhibit C.  Contractor shall pay AABS for such goods and/or services in accordance with the payment terms set forth on Exhibit C.  All terms are FOB Project Site (as identified on Exhibit A).  Risk of Loss on each Phase of Units shall pass to Contractor once the Units in that Phase have been Rough Set on Owner’s Foundation and AABS provides Contractor with a Notice of Completion of Rough Set.

	
3.  

	
Delays and Contract Price Adjustment.  Notwithstanding anything to the contrary contained in this Agreement, if AABS is delayed in performing any work under this Agreement because of delays caused by any act or omission of Owner or Contractor (or anyone acting on behalf of Owner or Contractor, including any agent, employee, subcontractor, independent contractor acting on their behalf), labor disputes, civil or military authority, fire, unavoidable casualties, causes beyond AABS’ control, delay caused by pending mediation or arbitration or other causes which AABS reasonably determines constitutes a “Scope Change” and therefore justifies delay or by changes ordered in the work (collectively “Owner’s/Contractor’s Delays”), the Contract Price shall be increased by an amount equal to the additional costs incurred by AABS in performing any such work that were caused by such Owner’s/Contractor’s Delays, or the sum of one thousand dollars ($1,000.00) per day, whichever is less. Increases in the Contract Price pursuant to this Section 3 shall be in addition to, and not in limitation of, any fees payable or costs reimbursable to AABS as otherwise provided for in this Agreement or any other adjustment in the Contract Price provided for herein. Notwithstanding anything to the contrary contained in this Agreement, if Contractor is delayed in performing any work under this Agreement because of delays caused by any act or omission of AABS or anyone acting on AABS’ behalf, including any agent, employee, subcontractor, or independent contractor of AABS (collectively, “AABS’ Delays”), AABS shall pay Contractor an amount equal to the additional costs incurred by Contractor that were caused by such AABS’ Delays, or one thousand dollars ($1,000.00) per day of AABS’ Delays, whichever amount is less. Neither party shall be entitled to an increase or reimbursement where a delay results from acts of God, acts of terrorism, strikes, wars, floods, hurricanes, tropical storms, tornados, fires, or other catastrophic events outside the control of AABS and Contractor (“Excusable Delays”). REGARDLESS OF CAUSE OR THE RIGHT TO AN ADJUSTMENT IN THE CONTRACT PRICE, EACH DAY OF DELAY WHICH IS NOT THE FAULT OF AABS SHALL EXTEND ALL STATED DEADLINES OF AABS AS SET OUT IN THE SCHEDULE BY AS MANY DAYS.

	
4.  

	
Owner’s and/or Contractor’s Responsibilities. Any and all Work in connection with the Project that is reasonably necessary for AABS to complete delivery of the goods and/or services contracted for hereunder, and which are not specifically and expressly identified as the responsibility of AABS, shall be the responsibility of the Owner and/or Contractor.

	
5.  

	
Inspection by Owner.  AABS shall provide Owner, Contractor, and their assignees (the “Inspecting Parties”) the opportunity to inspect the Work (the “Inspection”) at the Plant of Manufacture.  The Inspecting Parties must provide AABS with written notice (the “Inspection Notice”) of their desire to inspect the Work at least two (2) days prior to such Inspection.  Subject to the terms contained herein, once AABS receives the Inspection Notice, AABS shall schedule the Inspection and notify the Inspecting Parties of the scheduled time and date of the Inspection.  If AABS, in its sole discretion, is not able to schedule the Inspection for the time and date requested by the Inspecting Parties in the Inspection Notice, AABS shall provide the Inspecting Parties with alternate Inspection times and/or dates.  The Inspecting Parties shall choose one of the alternate times and/or dates and notify AABS of their choice.  AABS shall then schedule the Inspection on the chosen time and/or date.

	
6.  

	
Limited Warranty.  Subject to the conditions and limitations set forth in this Section 6, and subject to Owner’s compliance with the Customer Service Manual (Exhibit J), AABS warrants to Contractor for the Warranty Period (as defined below) that any buildings constructed by AABS shall conform to the Plans, meet the requirements of a residence hall, and be free of material defects in the workmanship and the materials provided by AABS.  The Warranty Period for each Building shall commence on the earlier of (i) the Substantial Completion of the Project or (ii) September 15, 2011, and shall terminate at 5:00 p.m. (local time) on the 365th day following the day of the commencement of said Warranty Period. This Warranty excludes labor, services, materials and/or equipment supplied by anyone other than AABS.

	
7.  

	
Warranty Claims. In the event that, during the Warranty Period, Contractor shall discover the existence of Defective Work, Contractor shall provide written notice of such Defective Work to AABS prior to the termination of the Warranty Period.  Within ten (10) days after receipt of a Warranty Claim, AABS will notify Contractor of its acceptance or denial of all or any part of the Warranty Claim, which acceptance or denial shall be determined by AABS in the exercise of its sole discretion, subject, however, to the following criteria:

	
  

	
(i)

	
Any item listed on Contractor’s Warranty Claim that in fact complies with the Plans shall not constitute Defective Work.

	
  

	
(ii)

	
Any item listed on Contractor’s Warranty Claim that involves labor or materials not specifically identified as within the Scope of Work AABS is to perform under Exhibit B shall not constitute Defective Work.

	
  

	
(iii)

	
Any item listed on Contractor’s Warranty Claim that was caused by an event or occurrence after Substantial Completion of all the work which AABS is responsible for performing under Exhibit B shall not be deemed to be Defective Work unless directly and solely caused by an act or omission of AABS after such Substantial Completion.

	
(iv)  

	
Any item listed on Contractor’s Warranty Claim that was caused by or was the result of work performed by Contractor, Owner, or their respective agents, employees, contractors or any other persons or entities other than AABS, including, but not limited to, damage caused by connection to water, sewer, electric, gas, phone or communication or other systems, shall not be deemed to be Defective Work.  This Subsection shall not apply to damage caused solely by AABS or its respective agents, employees, or contractors.  For example, if Contractor connects the water incorrectly and certain Units flood, the flood and any resulting damage shall not be deemed to be Defective Work.  However, if the Contractor connects the water correctly, but a problem with the pipes installed by AABS in a certain Unit leak, the defective pipes would be deemed Defective Work (assuming there are no other issues that would prevent the problem with the pipes from being deemed Defective Work).

	
8.  

	
DISCLAIMER OF WARRANTIES.  EXCEPT AS SET FORTH HEREIN, AABS MAKES NO REPRESENTATIONS OR WARRANTIES, EXPRESSED OR IMPLIED, INCLUDING THE IMPLIED WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE.  AABS DOES NOT AUTHORIZE, NOR DOES IT ADOPT, CONFIRM, OR RATIFY, ANY WARRANTY OR REPRESENTATION MADE BY ANY PERSON OR ANY OTHER SOURCE REGARDING THE GOODS AND/OR SERVICES SOLD OR PROVIDED UNDER THIS AGREEMENT, OTHER THAN THOSE SPECIFICALLY DESCRIBED ELSEWHERE IN THIS AGREEMENT.  THE EXCLUSIVE REMEDY IS LIMITED TO REPAIR OR REPLACEMENT, AT AABS’ OPTION, OF THE DEFECTIVE WORK.  AABS SHALL NOT BE LIABLE FOR ANY LOSS OR DAMAGES, INCLUDING LOST PROFITS, OR ANY OTHER INCIDENTAL OR CONSEQUENTIAL DAMAGES ARISING IN ANY MANNER FROM THIS WARRANTY OR CLAIMS HEREUNDER.  THERE ARE NO WARRANTIES WHICH EXTEND BEYOND THE DESCRIPTION ON THE FACE HEREOF.

 

	
9.  

	
Prevailing Wages.  Contractor represents and warrants to AABS that there are no state, county or local laws, ordinances, codes, rules or regulations that affect the wages to be paid to those laborers, mechanics, carpenters and other skilled tradesmen employed by AABS other than standard Wage and Hour requirements impacting overtime.  Contractor further warrants that the provisions of Section 212(a) of the National Housing Act, as amended, regarding the payment of prevailing wage rates do not apply to this Project.  If Section 212(a) or any state, county or local laws, ordinances, codes, rules or regulations now or hereafter exist that increase the cost to AABS of performance of its obligations under this Agreement, the Contract Price shall be increased by the amount of the increase in cost of performance by AABS.

 

	
  

	
10.

	
Insurance.  Owner or Contractor shall secure and maintain at its own expense insurance covering general liability and property damage in an amount of not less than one million dollars ($1,000,000) per occurrence and not less than two million dollars ($2,000,000) general aggregate, as well as additional excess liability of not less than three million dollars ($3,000,000).  Contractor shall furnish a certificate of such insurance to AABS and will promptly pay all premiums on said policy as when the same becomes due and shall name AABS as an additional insured.  AABS shall provide Contractor a copy of AABS property damage and liability insurance coverage, which shall match Owner’s or Contractor’s coverage amounts outlined above.  Said policy shall name Contractor as an additional insured for damage and/or incident, as covered in the policy, to the Modular Units that are the subject of this Agreement.  Subject to the limitations outlined in Section 2 above, AABS’ insurance and/or the insurance of AABS’ subcontractors shall cover each Phase of Units until the Units in that Phase have been Rough Set on Owner’s Foundation.  AABS shall also maintain proper worker’s compensation insurance coverage as required by the states of Colorado and Wyoming for all worked performed in Colorado or Wyoming, respectively.  AABS shall furnish a certificate of such insurance to Contractor.

 

	
  

	
11.

	
Indemnity.  To the fullest extent permitted by law, Contractor agrees to indemnify, defend, and hold harmless AABS and its officers, agents, employees and subcontractors from and against any and all claims, losses, damages, and liabilities, including all costs of litigation and attorneys’ fees, personal injury (including death) and destruction of tangible property, arising out of, or resulting from, this Agreement.  Notwithstanding the above, Contractor shall not be required to defend, indemnify or hold harmless AABS, its employees, agents, subcontractors or anyone employed directly or indirectly by any of them for their own respective negligent acts or omissions.  This provision shall survive the Substantial Completion of the Work and/or termination of this Agreement.

To the fullest extent permitted by law, AABS agrees to indemnify, defend, and hold harmless Contractor and its officers, agents and employees from and against any and all claims, losses, damages, and liabilities, including all costs of litigation and attorneys’ fees, personal injury (including death) and destruction of tangible property, arising out of, or resulting from, the negligent acts or omissions that are solely attributable to AABS, its employees, agents, subcontractors or anyone employed directly or indirectly by any of them.  Notwithstanding the above, AABS shall not be required to defend, indemnify or hold harmless the Contractor, its employees, agents, subcontractors or anyone employed directly or indirectly by any of them for their own respective negligent acts or omissions.  This provision shall survive the Substantial Completion of the work and/or termination of this Agreement.

	
  

	
12.

	
Governing Law.  This Agreement shall be governed by the laws of the State of Colorado.

	
  

	
13.

	
Dispute Resolution.  Contractor and AABS will attempt to resolve any dispute arising out of their business relationship through good faith negotiation by officers empowered to make decisions.  If the dispute cannot thus be resolved, the parties shall submit the dispute to non-binding mediation administered by a mutually agreeable mediation group.  Mediation shall be held in Denver, Colorado.  If the dispute cannot be resolved through mediation, the parties shall submit the dispute to arbitration administered by a single arbitrator, selected by the parties, in accordance with the American Arbitration Association Commercial Arbitration Rules and judgment on the award by the arbitrator may be entered in any court having jurisdiction thereof.  Arbitration shall be held in Denver, Colorado.  To the fullest extent permitted by law, the prevailing party shall be entitled to its reasonable attorneys’ fees from the losing party.

	
  

	
14.

	
Trade Usage. Contractor and AABS have expressed all of their respective rights and obligations in this Agreement.  Trade usage shall neither be applicable nor relevant to this Agreement nor be used in any manner to explain, qualify, or supplement any of the terms of this Agreement.

	
  

	
15.

	
Assignment.  Neither Contractor nor AABS shall assign its interest in this Agreement without the written consent of the other.

	
  

	
16.

	
Lien Rights.  Nothing in this Agreement shall limit any rights or remedies that AABS may have under lien laws (legal or equitable) including, but not limited to, the Uniform Commercial Code and the laws of the jurisdiction of the Project applicable to liens of vendors or construction contractors.

	
  

	
17.

	
Publication.  Contractor grants AABS a license to use photographic images of the Buildings and the name of the Project in AABS’ advertising without royalty or other remuneration.  Additionally, Contractor authorizes AABS to reference this Project in AABS’ press releases, marketing literature and other promotional items.

	
  

	
18.

	
Taxes.  AABS shall be responsible for the payment of any sales tax for materials, products, or services sold to Contractor hereunder, and AABS shall be responsible for any applicable use, local, or state taxes.  Any and all such taxes which may be imposed on AABS in connection with the performance of the Work which AABS is responsible for performing under Exhibit B and the provision of goods and/or services to Contractor shall be the responsibility of AABS.

	
  

	
19.

	
Licenses and Permits.  AABS shall, at its own expense, obtain the necessary licenses and permits required by Casper, Wyoming for AABS and its agents, employees and subcontractors to perform the Work which AABS is responsible for performing under Exhibit B.  Any additional licenses or permits shall be the sole responsibility of the Owner or Contractor.

	
  

	
20.

	
Additional Documents.  Subject to the following exceptions and limitations contained herein, AABS agrees to be bound to the Contractor by the terms and conditions of the Standard Form of Agreement Between Owner and Contractor (“A111”) between Casper College and Caspar/Pope Joint Venture dated September 10, 2009 and the General Conditions of the Contract for Construction (“A201”) (collectively, the “Casper Contract Documents”) applicable to subcontractors.  In the event of any conflict between any provision of this Agreement and any provision of the Casper Contract Documents, the provision of this Agreement shall control.  Additionally, AABS specifically rejects the following provisions of the Casper Contract Documents, if such provisions are applicable to AABS, such that the terms and conditions of such provisions shall not apply to this Agreement or the relationship between Contractor and AABS: Article 9 of A111; Article 11 of A111; Section 12.1.4 of A111 except for Subsections 12.1.4.2 – 12.1.4.5; and Section 3.5.3 of A201.

	
  

	
21.

	
Entire Agreement.  This Agreement is the entire agreement between Contractor and AABS and supersedes all prior agreements, whether written or oral, between the parties with respect to the subject matter, constitutes a complete statement of the terms of agreement between the parties, and supersedes any and all prior agreement or understandings between the parties.  This Agreement may not be amended, supplemented, or otherwise modified except by a written agreement executed by the parties hereto.

  

  

  

 

EXHIBIT C

PURCHASE PRICE/TRANSFER OF OWNERSHIP

CONTRACT PRICE:  Seven Million Nine Hundred Eighty Nine Thousand One Hundred Ninety Two Dollars ($7,989,192.00).

TERMS:  On the Effective Date, Contractor shall (i) pay AABS Five Hundred Thousand Dollars ($500,000.00) (“Initial Payment”) and (ii) deposit Six Hundred Ninety Eight Thousand Three Hundred Seventy Eight and 80/100 Dollars ($698,378.80) ("Escrow Funds") into an escrow account (the "Escrow Account") accessible by AABS.  Subject to the conditions outlined below, once the first modular unit to be built under this Agreement is completed and ready to ship, AABS shall be entitled to draw the amount of One Hundred Thousand Dollars ($100,000.00) (the “Escrow Draw”) from the Escrow Account on a weekly basis, unless such amount is not available in the Escrow Account, then the Escrow Draw for that week shall be the remaining amount available in the Escrow Account.  AABS shall be entitled to receive the Escrow Draw once the Contractor and AABS both sign the weekly escrow release (the “Escrow Release”) indicating that the project contemplated by this Agreement (the “Project”) is substantially on schedule at the time of the scheduled Escrow Draw.  If the Project is not substantially on schedule at the time of a scheduled Escrow Draw, Contractor may choose to withhold its signature on the Escrow Release until such time as the Project is substantially back on schedule.  All Escrow Draws after the original Escrow Draw shall be scheduled one (1) week from the date Contractor signs the applicable Escrow Release.  Contractor shall not unreasonably withhold its signature on the Escrow Release.  AABS shall have no obligation to cause manufacturing of the modular units to commence prior to receipt of the Initial Payment and deposit of the Escrow Funds into the Escrow Account.

Prior to shipment of the modular units sold by AABS to Contractor, Contractor shall pay the total invoice amount for each such modular unit less (i) fifteen percent (15%) of the total invoice amount, which consists the portion of the Initial Payment and Escrow Funds applicable to these modular units that shall have been previously paid by Contractor, (ii) the retainage (as outlined below), and (iii) the amounts previously paid by Contractor by two party check to the Specialty Suppliers (defined below) for the materials or services applicable to these modular units.  The Specialty Suppliers shall be those suppliers listed on Exhibit 1 to this Exhibit C.

All onsite work to be completed by the end of the month, including the cost of set, interior carpentry finish, and delivery, shall be billed to Contractor by AABS using the “Subcontractor’s Application for Payment” form (the “Application for Payment”). All Applications for Payment shall be submitted to Contractor by the 25th of the month in which the work represented by the billing is performed.  Payment, less (i) fifteen percent (15%) of the Application for Payment, which consists the portion of the Initial Payment and Escrow Funds applicable to the onsite work that shall have been previously paid by Contractor, and (ii) the amounts previously paid by Contractor by two party check to the Specialty Suppliers for the materials or services included in the Application for Payment, shall be due thirty (30) days from the date of billing.

The Contractor shall, within (7) days after receipt of an Application for Payment, issue to AABS a written acknowledgement of receipt of the Application for Payment, which shall indicate the amount the Contractor has determined to be properly due and, if applicable, the reasons for withholding payment in whole or in part.

Ten percent (10%) of the amounts due and owing for the modular units shall be retained by Contractor until such time as AABS provides a written notice of the completion (the “Notice of Completion”) of the Project.  From the date of the Notice of Completion, Contractor shall have ten (10) days to complete and inspect the individual modular units and create a punch list for any items deemed defective.  AABS shall then complete any necessary repair of any actual defective item.  Within sixty (60) days of receipt of the Notice of Completion, Contractor shall pay the retainage amount to AABS upon receipt of (i) the final invoice applicable to the units and (ii) AABS’ written confirmation of completion of repair of any actual defective items.

Interest shall accrue on any amount overdue at the rate of fifteen percent (15%) per annum or the maximum amount allowed by Colorado Law, whichever is less.

  

  

  

EXHIBIT D

DEFINITIONS RIDER

As used in this Agreement for Sale of Modular Buildings, the following terms have the following meanings.

1. Acceptance of Goods.  Contractor has inspected and determined that Units are substantially complete in accordance with the contract such that they can be utilized by Owner for the intended use.

2. Building.  The Buildings are more particularly described in the signed plans set forth on Exhibit F.

3. Defective Work.  Work that is not free of defects in workmanship or materials or which does not otherwise conform to the Specifications or the Plans.

4. Delivery.  Transportation is to be facilitated by AABS from the manufacturing facility to the Work Site.

5. Exterior Finish.  All siding, soffit fascia and trims.

6. Foundation.  That permanent foundation, compliant with building codes and all other applicable regulations, ordinances and statutes, to which Modular Units will be permanently affixed or stacked.

7. Foundation Tolerances.  The tolerances for the level surface and horizontal directions of the Foundation and the attached sill plate for the Buildings to be produced and provided by AABS pursuant to this Agreement.  Foundation Tolerances are as follows: all horizontal, vertical and elevation dimensions shall have a tolerance of no more than 1⁄4 inch +/- and all diagonal dimensions shall have a tolerance of no more than 1⁄2 inch +/-.

8. Modular Unit or Unit.  A structural component of a Building to be provided by AABS.

9. Order.  The written direction by Contractor for AABS to commence to purchase parts for and to manufacture Modular Units.  The Contractor shall specify in the Order the model, colors, materials and other particulars for the Modular Units comprising a Building and shall identify the intended Work Site.

10. Plans. Drawings and other specifications for Modular Units approved by Contractor and Owner prior to placement of an Order.

11. Plant of Manufacture.  The manufacturing facility where the Modular Units are constructed.

12. Pre-Delivery Inspection.  Inspection by Contractor upon AABS’ Substantial Completion of the manufacture of the Modular Units prior to Delivery.

13. Rough Set.  The removal of a Modular Unit from a delivery carrier and the affixation of the Modular Unit to its Foundation and connection to adjacent Modular Units.

14. Specifications.  Those specifications which are attached hereto as Exhibit F.

15. Substantial Completion.  The point at which AABS completes all of the items that it is required to complete, as indicated on the Scope of Work included as Exhibit B, except for those minor “punch list” items that do not prevent a Certificate of Occupancy from being issued.

16. Uniform Commercial Code.  The Uniform Commercial Code as applicable in the jurisdiction of the Work Site.

17. Warranty.  The limited warranty set forth in Section 10 of the Terms and Conditions of Sale.

18. Warranty Claim.  A claim, or a notice of a claim, by Contractor for correction or remediation of Defective Work pursuant to the Warranty.

19. Work Site. Location of Project where AABS is to deliver and install Modular Units.

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00182-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00182-of-00352.parquet"}]]