Document:

[This
Document has been Translated from Chinese to English]

 

Supplemental
Agreement to the Project Financing Agreement

 

This Supplemental Agreement
(the “Agreement”) is made and entered into by and among the following parties on January 26, 2012.

 

(1)    
Tianjin Cube Xindao Equity Investment Fund Partnership (LLP), Tianjin Cube Xinde Equity Investment Fund Partnership (LLP),
Tianjin Cube Xinren Equity Investment Fund Partnership (LLP) and Tianjin Cube Xinyi Equity Investment Fund Partnership (LLP) (hereinafter
referred to as “Cube” collectively), which are limited partnerships duly incorporated and legally existing under
the laws of the People’s Republic of China (“PRC” or “China”).

 

(2)    
Tsining Housing Development Co., Ltd. (the “Borrower” or “Tsining”), which is a limited
liability company duly incorporated and legally existing under the laws of China, with its address at No. 9, Baqiao South Road,
Baqiao District, Xi’an City.

 

(3)    
Clever Advance Limited (the “Pledgor” or “Hong Kong Clever”), which is a limited liability
company duly incorporated and legally existing under the laws of Hong Kong.

 

Whereas:

 

	I.		With respect to the financing matters of Xi’an Baqiao A and Baqiao B Project
(the “Financing”), each party has already jointly or respectively executed the Project Financing Agreement,
the Financial Advisor Agreement, the Transaction Arrangement Agreement for the Xi’an Baqiao A and Baqiao B Project Financing,
the Financial Regulatory Agreement and the supplementary agreements to the above-mentioned agreements (the “Financing
Transaction Documents” collectively).

 

	II.		After the execution of the Financing Transaction Documents, Cube disbursed the entrustment
loan totaling RMB 200,000,000 (the “Entrustment Loan”) to Tsining via China Construction Bank Shaanxi Branch
(the “Bank”). The Bank and the Borrower signed the Entrustment Loan Agreement (Jian Shan Ying Wei Dai No. (2011)
001-004).

 

	III.		Tsining has not obtained the land use rights to Baqiao A and Baqiao B Project on time
due to the fact that the government did not have available land quotas. After consultation between them, both Cube and Tsining
intend to clarify and supplement to the specific usage terms of the Entrustment Loan.

 

	IV.		The Entrustment Loan will expire on January 27, 2012, and the Tsining applies for
a six-month renewal.

 

Accordingly, each party reaches the Supplemental
Agreement as follows:

 

Article 1: The Use of the Entrusted
Loan

 

	1.1		According to the Transaction Arrangement Agreement for the Xi’an Baqiao A and
Baqiao B Project Financing, Cube agreed that Tsining may purchase the equity interest of Shanxi Bihu Real Estate Development Co.,
Ltd using RMB 30,000,000 of the Entrusted Loan. Considering that Tsining has not purchased such equity interest, Tsining agrees
to transfer back the RMB 30,000,000 mentioned above to the joint account held by Cube and Tsining no later than February 29, 2012,
and use it in accordance with this Agreement, unless Cube otherwise agrees.

 

	1.2		Provided that Tsining satisfies the terms and conditions of this Agreement, Cube agrees
to use already disbursed Entrusted Loan for the Borrower’s “Xinqingfang” real estate project (“Xinqingfang
Project”) which is located at No. 66 Huzhu Road, Xi’an in the following ways:

 

	(1)		No more than RMB 150,000,000 of the Entrustment Loan shall be used in buying the state-owned
land use right of Xinqingfang Project (“Project Land”). Specifically, no more than RMB 100,000,000 can be used
to pay the trade margins in order to participate in the listing and auction of the Project Land, and upon receiving the confirmation
letter, no more than RMB 50,000,000 can be used to pay the land assignment cost. However, Tsining promises to pay the excess using
its own funds if the land assignment cost exceeds the amount mentioned above.

 

    	 

    	 

    
 

 

	(2)		Tsining could use the remaining balance of the Entrustment Loan to fund the Xinqingfang
Project or pay other upfront costs.

 

	1.3		Concerning the usage of the money stipulated in Clause 1.2 (1) and (2),
Cube and Tsining agree to put them in a jointly managed account that is monitored by the two parties before paying the money to
any payee. The seals of the jointly managed account will be kept by the representatives appointed respectively by the two parties.
If it is necessary to pay to someone from this account, the two seals controlled by Cube and Tsining must be used together. If
the jointly managed account has an online banking payment function, Tsining must ensure that the payment from the jointly managed
account be completed only after obtaining Cube’s authorization. In addition, concerning Tsining utilizing the capital in
the Entrusted Loan, Cube will appoint relevant personnel for the purposes of an monitoringthe account. Cube will monitor the actual
usage of the Entrusted Loan in accordance with the provisions stipulated in this Agreement, in order to ensure that the usage
of the Entrusted Loan by the Tsining complies with provisions in this Agreement.

 

 

Article 2: The Guarantee of the
Entrusted Loan

 

	2.1		Besides the already existing guarantee measures for the Entrusted Loan, Tsining and
its affiliated companies agree to provide the following guarantee measures to Cube:

 

	(1)		Upon the signing of this Agreement, Tsining and its affiliated companies shall offer
the following temporary security guarantees:

 

	a)		Two (2) sets of commercial properties totaling 2,053.23 square meters owned by Tsining,
which are located at “Xinxing Building” No. 88-89 Jianguo Road, Beilin District, Xi’an, shall be used as security
guarantees for the Entrusted Loan;

 

	b)		Twenty-five (25) residential properties totaling 1,579 square meters owned by Shaanxi
Xinxing Construction Project Co., Ltd. (hereinafter referred to as “Xinxing Construction”), which are located
at Junjingyuan I, No. 369 Jinhua North Road, Xincheng District, Xi’an, shall be used as security guarantees for the Entrusted
Loan;

 

	c)		Seven (7) factory buildings totaling 16,351.79 square meters owned by Xi’an
Tianma Machinery Factory (hereinafter referred to as “Tianma Machinery Factory”), which are located at No.
66 Huzhu Road, Beilin District, Xi’an, shall be used as security guarantees for the Entrusted Loan.

 

(For an inventory of the above-mentioned
mortgage properties, see Appendix A hereto. The properties are collectively referred to herein as the “Temporary
Mortgages”).

 

For the aforementioned Temporary
Mortgages, Tsining shall maintain insurance approved by Cube.

 

	(2)		After the approval of the responsible local bureau of commerce, the parent company
of Tsining, Hong Kong Clever, shall use 100% of the equity of Tsining held by it to offer a equity pledge guarantee for the Entrusted
Loan, and shall complete the registration formalities for the equity pledge with the applicable industrial and commercial registration
department, and Cube shall be the first-order pledgee.

 

Cube agrees that after the above-mentioned
equity pledge is finished, the pledge of 100% of the equity of the Xi’an Disuo Trade and Business Co., Ltd. held by Xi’an
Xinxing Property Management Co., Ltd. shall be lifted.

 

	(3)		The other guarantors for the Entrusted Loan agree to use the guarantee measures offered
by them previously to continue tendering a guarantee for the Entrusted Loan, and at this point, to offer a written confirmation
to Cube (for a form of its contents, see Appendix B hereto) for confirmation.

 

    	 

    	 

    
 

 

	(4)		Tsining agrees that within fifteen (15) business days from the day of obtaining the
Xinqingfang Project land use right certificate, Tsining will use the Xinqingfang Project land use right and the construction in
process (if applicable) as a security guarantee for the Entrusted Loan, and Cube (or the Bank) will be the first-order mortgagee
of this security guarantee. Before this, Cube shall appoint personnel to be responsible for keeping the original of the Xinqingfang
Project land use certificate. After going through the registration formalities for the above-mentioned mortgages for the Xinqingfang
Project land, and if the mortgage rate of the Entrusted Loan (mortgage rate = assessed value of all the security guarantees for
the Entrusted Loan approved by Cube ÷ remaining sum of the principal of the Entrusted Loan ×100%)
is not less than 50%, Cube agrees that the registration for the Temporary Mortgages shall be lifted;

 

	(5)		Tsining shall use all the present and future accounts receivable of Xinqingfang Project
owned by Tsining to tender a guarantee to Cube.

 

	2.2		The aforementioned guarantee measures stipulated in Clause 2.1(1) to (3)
are the prerequisites for Tsining to use the Entrusted Loan in accordance with this Agreement. If registration is needed,
unless otherwise consented to by Cube in writing, Tsining shall ensure that the mortgage or pledge must be registered under Cube
or under the name of the Bank within fifteen (15) business days after the execution of this Agreement.

 

	2.3		Since the “Changanjiyong (2000) No. 2” Collective Land Use Right Certificate
(which contains an area of 1055.684 acres of land) held by Tsining’s subsidiary—Xi’an Suodi Trading Company
could not be used in the mortgage registration by the registration authority at present, Cube agrees that the aforementioned collective
land use right will not be used as mortgage guarantee for the Entrusted Loan.

 

Article 3: Undertakings of Tsining

 

	3.1		Tsining agrees it will ensure that the land used for the project can be publicly sold
by listing on 31st January, 2012 at the latest, and obtain the certificate for use of the land no later than 31st
March, 2012.

 

	3.2		Tsining promises to Cube that, with regard to the development and construction of
Xinqingfang Project:

 

	(1)		The progress of Xinqingfang Project and indexes of sales cash flow shall be in compliance
with the indexes listed in the table below:

 

	Development Indexes
	By the end of February 2012	Obtain land transaction confirmation
	By the end of March 2012	Obtain land certificate and mortgage the land to the entrusted loan lender
	By the end of April 2012	Obtain land use planning permit
	By the end of May 2012	Obtain construction project planning permit
	By the end of June 2012	Obtain construction permit and pre-sale permit
	Indexes
    of Sales Cash Inflow
	By the end of June 2012	RMB 70 million
	By the end of July 2012	RMB 150 million
	By the end of August 2012	RMB 250 million

 

	(2)		Starting February 2012, every month RMB 10 million shall be extracted from the sales
revenue of Junjingyuan Third Phase or other income recognized by Tsining other than the Xinqingfang Project to repay Cube the
principal on the loan until the principal of the loan and interests are fully paid.

 

    	 

    	 

    
 

 

If the index of cash flow generated
by any phase of Xinqingfang Project is not met, Tsining shall make up the difference with other income, and transfer them into
the account of the Xinqingfang Project supervised by Cube, which will be regarded as complying with the index.

 

If in any phase the development
index or the index of sales cash inflow under Clause 3.2(1) is not met, unless Cube and Tsining agree on other conditions
to the satisfaction of Cube, Cube will have the right to supervise and manage the banking account of Junjingyuan Third Phase.

 

	(3)		The monthly cash outflow of the Xinqingfang Project during its development process
shall not exceed the following budgets:

 

	Time and Place	Cash Expenditure Budget (RMB)	
         Usage 

	December 2011 to January 2012	RMB 230 million	Used for payment of land
	The First Quarter of 2012	RMB 30 million	Used for payment of initial cost of project, project funds and other relevant costs
	The Second Quarter of 2012	RMB 40 million
	July 2012 to August 2012	RMB 10 million

 

The above budgets are based on
the following assumptions: (a) land-transferring fees to be paid shall be no more than RMB 230 million; if they exceed that, the
above budgets can increase accordingly; (b) land-transferring fees and/or transaction bonds began to be paid in December 2011;
if the time is delayed, the budget schedule would also be delayed accordingly; (c) the project will be pre-sold starting June 2012;
if the presale is conducted ahead of schedule, Cube can negotiate with Tsining to adjust the budget. The above data can be further
adjusted if both parties agree.

 

	(4)		The monthly lowest price and the monthly average price of Xinqingfang Project shall
not be lower than those listed in the table below:

 

	Type
    of Property	The
    Monthly Lowest Price/RMB 	Monthly
    Average Price/RMB
	Ordinary Residence	6,000	7,000
	Small Apartment (blank)	6,000	7,000
	Shop on Ground Floor	12,000	15,000
	Commercial Plaza	18,000	21,000

 

If any pre-sale (or sale) price
is lower than the above ones, Tsining must notify Cube ahead of time and obtain approval from Cube.

 

	(5)		Since the “Xi’an Baqiao A and Baqiao B Project” stipulated previously
by the two parties in the Financing Transaction Documents is no longer applicable, except otherwise provided by this Agreement,
Cube agrees that Tsining should continue monitoring the inflow and outflow of capital of Xinqingfang Project in accordance with
the capital supervision measures stipulated in the Capital Supervision Agreement signed on 12 (month) 6 (day) 2011 by the two
parties. In the Capital Supervision Agreement, “Xi’an Baqiao A and Baqiao B Project” will be replaced
as Xinqingfang Project.

 

	(6)		According to the requirements of Cube, Tsining agrees to maintain appropriate insurance
for the in-progress constructions of the Xinqingfang Project.

 

	3.3		Tsining hereby agrees that after this Agreement goes into effect until Tsining repays
all the loans and related costs, Tsining will observe and satisfy the following unless the prior written consent of Cube is first
obtained:

 

	(1)		Tsining agrees that when it issues and distributes documents (including the formal
reports, notices, statements, etc.) relating to Xinqingfang Project to its shareholders, it will send a copy of
these documents to Cube.

 

	(2)		After signing this Agreement, Tsining shall provide Cube the following files:

 

    	 

    	 

    
 

 

	a)		Within the Entrust Loan period, before the 15th of each month, Tsining
shall submit to Cube the previous month’s bank statements of the jointly managed account and bank statements from other
bank accounts of Tsining;

 

	b)		Before the 15th of each month, Tsining shall submit to Cube the previous
month’s unaudited financial statements;

 

	c)		Tsining shall submit to Cube the weekly sale and operation information of Xinqingfang
Project after sales begin.

 

	(3)		If any of the following circumstances occur, Tsining must give Cube advance written
notice in and obtain Cube’s approval:

 

	a)		If any expenditure of Tsining’s will exceed RMB 1,000,000 and is not included
in the originally agreed upon budget;

 

	b)		If Tsining’s monthly spending will exceed RMB 3,000,000.

 

In this clause, concerning the
items for which Tsining must obtain prior written consent of Cube, Cube shall reply to Tsining within three (3) business days after
Tsining submits a written notice (including emails). If such response time exceeds three (3) business days, this shall be considered
as the tacit approval of Cube.

 

	3.4		Tsining and its affiliates agree, except otherwise provided by this Agreement, that
Tsining and its affiliates will continue to observe and fulfill all the stipulations in the Financing Transaction Documents.

 

Article 4: Entrusted Loan’s
Extension

 

	4.1		Cube agrees to extend the Entrusted Loan by six (6) months upon its expiration date
of 27th January, 2012.

 

	4.2		Tsining shall pay Cube consulting fee for the extension period on the date Tsining
receives a written document in which the Bank agrees to give an extension for the loan, which is 6.8% of the loan in the extension
period.

 

	4.3		During the extension period of the Entrusted Loan, the monthly interest shall stay
the same.

 

Article 5: Termination of The Financing Transaction

 

	5.1		After signing this Agreement, Cube shall have right to terminate this financing transaction
in the following circumstances:

 

	(1)		Subject to a written waiver by Cube, the security described in Clause 2.1 (1)
to Clause 2.1 (3) of this Agreement cannot be satisfied on January 31, 2012;

 

	(2)		Subject to a written waiver by Cube, Tsining fails to acquire the land needed for
this project, or is unable to acquire such land before March 31, 2012;

 

	(3)		Cube has the right to terminate to terminate this transaction when there are conditions
that are due to the fault of Tsining as described in laws, regulations, this Agreement, or the financing transaction documents.

 

	5.2		If Cube terminates this financing transaction according to this provision, then the
loan will be due immediately, Cube and/or the bank shall have right to demand Tsining to pay back all the loans, all the interest
and fees, and also pay the penalties for breach of contract according to following, whichever is higher:

 

	(1)		20% of total amount of the loans issued by the bank; or

 

    	 

    	 

    
 

 

	(2)		0.0015% for each day of total amount of the loans, starting from the date of the issuance
of loans to the date of repayment of all the loans. Any fees paid by Tsining to Cube concerning this financing transaction will
not be returned.

 

In addition, Cube shall have right
to demand guarantees that Tsining will bear liabilities.

 

Article 6 Other Arrangements

 

	6.1		The governing law and resolution of dispute provisions of the Project Financing Agreement
shall also apply to this Agreement.

 

	6.2		This Agreement is the amendment and supplement to the financing transaction documents.
In case any arrangements in the financing transaction documents and relevant contracts or materials are different from those in
this supplementary agreement, this Agreement shall prevail.

 

	6.3		This Agreement and the financing transaction documents shall have the same legal effect.
Tsining shall be considered to have breached the contract if it violates the arrangements in this Agreement, Cube shall have right
to take proper action to protect its rights and interests according to the financing transaction documents and this Agreement,
including, but not limited to, announcing that the loan will be terminated before its due date, and demanding Tsining and other
parties to bear reasonable liabilities.

 

	6.4		This Agreement shall become effective after the affixation of the signatures of each
party’s authorized representatives in six copies, each party having three copies with equal legal validity.

 

(Remainder of page intentionally left blank)

    	 

    	 

    

Tianjin Cube Xindao Equity Investment Fund
Partnership (LLP)(Seal)

 

Tianjin Cube Xinde
Equity Investment Fund Partnership (LLP)

 

Tianjin Cube Xinren
Equity Investment Fund Partnership (LLP)

 

Tianjin Cube Xinyi
Equity Investment Fund Partnership (LLP)

 

Signature of the Authorized
Representative: /s/ Authorized Person

Name: Authorized Person

Title: Authorized
Person

 

Tsining
Housing Development Co., Ltd.                                                        (Seal)

 

Signature of the Authorized
Representative: /s/ Authorized Person

Name: Authorized Person

Title: Authorized
Person

 

Clever
Advance Limited                                                                                  (Seal)

 

Signature of the Authorized
Representative: /s/ Authorized Person

Name: Authorized Person

Title: Authorized
Person

 

Signature
Page to Supplemental Agreement to the Project Financing Agreement

 

    	 

    	 

    

Exhibit A: List of the Additional Collateral

 
  

	No.	Project	Address	Room No.	Floor	Area	Nature of Property	No. of Property Ownership Certificate	Owner
	1	Xinxing Mason	No. 88 Jianguo Rd, Beilin District	9-30201	2	277.03	Commercial	112510808IV-52-9-30201	Tsining Housing Development Co., Ltd.
	2	Xinxing Mason	No. 88 Jianguo Rd, Beilin District	9-30711	7	776.20	Commercial	112510808IV-52-9-30711	Tsining Housing Development Co., Ltd.
	Sub-total	2,053.23	 	 	 
	3	Xinqingfang	No. 66 Huzhu Rd, Beilin District	26	1	1,915.32	Industrial Factory	N/A	Tianma Machinery Factory
	4	Xinqingfang	No. 66 Huzhu Rd, Beilin District	1	4	3,488.32	Industrial Factory	N/A	Tianma Machinery Factory
	5	Xinqingfang	No. 66 Huzhu Rd, Beilin District	113	2	1,472.04	Industrial Factory	N/A	Tianma Machinery Factory
	6	Xinqingfang	No. 66 Huzhu Rd, Beilin District	6	2	2,406.48	Industrial Factory	N/A	Tianma Machinery Factory
	7	Xinqingfang	No. 66 Huzhu Rd, Beilin District	5	2	6,073.45	Industrial Factory	N/A	Tianma Machinery Factory
	8	Xinqingfang	No. 66 Huzhu Rd, Beilin District	7	2	996.18	Industrial Factory	N/A	Tianma Machinery Factory
	Sub-total	16,351.79	 	 	 
	9	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11108	11	123.18	Residential	1150110019-4-12-11108~1	Shaanxi Xinxing Construction Project Co., Ltd
	10	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11109	11	56.79	Residential	1150110019-4-12-11109~1	Shaanxi Xinxing Construction Project Co., Ltd
	11	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11111	11	56.10	Residential	1150110019-4-12-11111~1	Shaanxi Xinxing Construction Project Co., Ltd
	12	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11112	11	56.43	Residential	1150110019-4-12-11112~1	Shaanxi Xinxing Construction Project Co., Ltd
	13	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11113	11	56.43	Residential	1150110019-4-12-11113~1	Shaanxi Xinxing Construction Project Co., Ltd
	14	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11115	11	55.23	Residential	1150110019-4-12-11115~1	Shaanxi Xinxing Construction Project Co., Ltd
	15	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11120	11	54.85	Residential	1150110019-4-12-11120~1	Shaanxi Xinxing Construction Project Co., Ltd

 

 

    	 

    	 

    

 

	16	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11118	11	55.15	Residential	1150110019-4-12-11118~1	Shaanxi Xinxing Construction Project Co., Ltd
	17	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11208	12	123.18	Residential	1150110019-4-12-11208~1	Shaanxi Xinxing Construction Project Co., Ltd
	18	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11209	12	56.79	Residential	1150110019-4-12-11209~1	Shaanxi Xinxing Construction Project Co., Ltd
	19	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11210	12	56.79	Residential	1150110019-4-12-11210~1	Shaanxi Xinxing Construction Project Co., Ltd
	20	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11212	12	56.43	Residential	1150110019-4-12-11212~1	Shaanxi Xinxing Construction Project Co., Ltd
	21	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11219	12	55.15	Residential	1150110019-4-12-11219~1	Shaanxi Xinxing Construction Project Co., Ltd
	22	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11211	12	56.10	Residential	1150110019-4-12-11211~1	Shaanxi Xinxing Construction Project Co., Ltd
	23	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11213	12	56.43	Residential	1150110019-4-12-11213~1	Shaanxi Xinxing Construction Project Co., Ltd
	24	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11214	12	54.46	Residential	1150110019-4-12-11214~1	Shaanxi Xinxing Construction Project Co., Ltd
	25	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11215	12	55.23	Residential	1150110019-4-12-11215~1	Shaanxi Xinxing Construction Project Co., Ltd
	26	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11216	12	53.79	Residential	1150110019-4-12-11216~1	Shaanxi Xinxing Construction Project Co., Ltd
	27	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11217	12	55.15	Residential	1150110019-4-12-11217~1	Shaanxi Xinxing Construction Project Co., Ltd
	28	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11218	12	55.15	Residential	1150110019-4-12-11218~1	Shaanxi Xinxing Construction Project Co., Ltd
	29	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11220	12	54.85	Residential	1150110019-4-12-11220~1	Shaanxi Xinxing Construction Project Co., Ltd
	30	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11110	11	56.79	Residential	1150110019-4-12-11110~1	Shaanxi Xinxing Construction Project Co., Ltd
	31	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11114	11	54.46	Residential	1150110019-4-12-11114~1	Shaanxi Xinxing Construction Project Co., Ltd

 

 

    	 

    	 

    

 

	32	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11116	11	53.79	Residential	1150110019-4-12-11116~1	Shaanxi Xinxing Construction Project Co., Ltd
	33	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11117	11	55.15	Residential	1150110019-4-12-11117~1	Shaanxi Xinxing Construction Project Co., Ltd
	34	Junjingyuan	No. 369 Jinhua North Rd, Xincheng District	12-11119	11	55.15	Residential	1150110019-4-12-11119~1	Shaanxi Xinxing Construction Project Co., Ltd
	Sub-total	1,579.00	 	 	 
	Total	19,984.02	 	 	 

 

 

 

 

    	 

    	 

    

 

Exhibit 2: Form of Letter of Confirmation
by Guarantor

 

Letter
of Confirmation of Security

 

The Letter of Confirmation is made and entered
into by and among following parties on [......], 201_:

 

	(1)		Shanxi Xinxing Construction Project Co., Ltd. (“Xinxing Construction”)
is a limited liability company duly incorporated and legally existing under the laws of China, with its address at No. 88, Jianguo
Road, Xi’an City.

 

	(2)		Xi’an Xindadi Development Co., Ltd. (“Xindadi”) is a limited
liability company duly incorporated and legally existing under the laws of China, with its address at No. 9, Baqiao Park West
Road, Baqiao District, Xi’an City.

 

	(3)		Xi’an Xinxing Property Management Co., Ltd. (“Xinxing Property”)
is a limited liability company duly incorporated and legally existing under the laws of China, with its address at Room 501, Fifth
Floor, No.6 Xinxing Hanyuan, Youyi East Road, Beilin District, Xi’an City.

 

	(4)		Wayfast Holdings Limited (“Wayfast Holdings”) is a limited liability
company duly incorporated and legally existing under the laws of British Virgin Islands.

 

	(5)		China Housing and Land Development Inc. (“China Housing”) is a
limited liability company duly incorporated and legally existing under the laws of United States.

 

	(6)		Pingji LU, a Chinese citizen.

 

(Each of the above parties shall be hereinafter
referred to as a “Party” respectively, and as the “Parties” collectively.)

 

Whereas:

 

	1)		With regard to the financing matters of Xi’an Baqiao A and Baqiao B Project
(the “Financing”), Tianjin Cube Xindao Equity Investment Fund Partnership (LLP), Tianjin Cube Xinde Equity
Investment Fund Partnership (LLP), Tianjin Cube Xinren Equity Investment Fund Partnership (LLP) and Tianjin Cube Xinyi Equity
Investment Fund Partnership (LLP) (the “Cube” collectively) has executed the Project Financing Agreement as
well as other relative agreements and legal documents (the “Financing Transaction Documents”) with Tsining
Housing Development Co., Ltd. (the “Tsining”), and has already disbursed the entrustment loan totaling RMB
200,000,000 (the “Entrustment Loan”) to Tsining via China Construction Bank Shanxi Branch (the “Bank”);

 

Each party has provided the mortgage, pledge
or guarantee to the Financing respectively, and has executed the below security agreements or security documents with Cube or the
Bank thereby:

 

	a)		The Guarantee Agreement signed between Xinxing Construction and Cube at the date of
Month/Date 201_;

 

	b)		The Guarantee Agreement signed between Xindadi and Cube at the date of Month/Date
201_;

 

	c)		Four Equity Pledge Agreements signed respectively between Xinxing Property and Cube
at the date of Month/Date 201_;

 

	d)		The Share Charge signed between Wayfast Holdings and Cube at the date of Month/Date
201_;

 

	e)		The Guarantee Agreement and Equity Pledge Agreement signed between China Housing as
well as Tsining and Cube at the date of Month/Date 201_;

 

	f)		The Entrustment Loan Guarantee Agreement signed between Pingji LU and Cube at the
date of Month/Date 201_.

 

    	 

    	 

    
 

 

(The below security agreements or security
documents shall be hereinafter referred to as “Security Documents” collectively )

 

During the process of performing the Project
Financing Agreement, the Supplemental Agreement to the Project Financing Agreement (the “Supplemental Agreement”)
is made and entered into by and between Cube and Tsining at the date of Month/Date 201_.

 

In order to clarify the security liabilities
provided by each party to Cube for Xining, each party represents and warrants that:

 

	1)		Each party understands and confirms that the Supplemental Agreement is made and entered
into by and between Cube and Tsining at the date of Month/Date 201_. Each party is aware of and consent to the Supplemental Agreement
signed by Tsining. In particular, each party agrees that Cube provide a six-month extension to the loan of Tsining on the basis
of the original loan term.

 

	2)		The parties consent to continuously secure the obligations under the Financing Transaction
Documents and the Supplemental Agreement for Tsining. If there are amendments or supplements to the terms of the Security Documents
that have been signed by one party or the parties, one party or the parties shall be liable to the terms that have been amended
or supplemented. Particularly, regarding the joint and severable guarantee liabilities borne by each party pursuant to the Security
Documents, the parties agree that the term of guarantee shall be two years from the expiration date after the six (6) month extension
of the loan term.

 

	3)		This Letter of Confirmation shall become effective on the date of execution.

 

(Remainder of page intentionally left blank)

 

    	 

    	 

    

Shanxi Xinxing Construction Project Co.,
Ltd.    (Seal)

 

By Authorized Agent

 

Xi’an Xindadi Development Co., Ltd.                   (Seal)

 

By Authorized Agent

 

Xi’an Xinxing Property Management
Co., Ltd. (Seal)

 

By Authorized Agent

 

Wayfast Holdings Limited                                        (Seal)

 

By Authorized Agent

 

China Housing and Land Development Inc.       (Seal)

 

By Authorized Agent

 

Pingji LU

 

Signature: _______________________

 

Signature
Page of the Letter of Confirmation of SecuritySEPARATION AND GENERAL RELEASE AGREEMENT

 

THIS SEPARATION AND GENERAL RELEASE AGREEMENT
(the “General Release”) is made as of this 1st day of February, 2012, by and between IntraLinks, Inc.
(the “Company”), and J. Andrew Damico (the “Executive”), on the other hand.

 

WHEREAS, Executive and the Company are
parties to an employment agreement dated February 26, 2008 (the “Employment Agreement”) which, upon specified termination
events, provided Executive with certain benefits provided that, among other things, the Executive enters into an agreement releasing
the Company of all claims against the Company and related persons and entities;

 

WHEREAS, on December 15, 2011, Executive separated
from his position of President and Chief Executive Officer but, at the request of the Company, continued thereafter his employment
with the Company in a non-executive capacity to assist in the transition of Executive’s responsibilities; and

 

WHEREAS, in lieu
of any termination benefits that Executive may have been entitled to under the Employment Agreement and in exchange for, among
other things, Executive’s agreement to the terms of this General Release, the Company shall provide Executive with the separation
benefits described below;

NOW, THEREFORE, in consideration of the
mutual covenants and other good and valuable consideration set forth herein, the Parties hereby agree as follows:

1.Termination
of Employment. Executive’s employment with the Company and any and all of its affiliated entities shall separate for
all purposes effective as of the 1st day of February, 2012 (the “Termination Date”). The Company shall pay
Executive’s salary and for his accrued but unused vacation through the Termination Date. The Company shall reimburse Executive
for any outstanding, reasonable business expenses that Executive has incurred on the Company’s behalf through the Termination
Date in accordance with the Company’s reimbursement policies.

2.Severance
Pay. In consideration of the Executive’s agreement to the terms and conditions contained in this General Release, the
Company shall pay the Executive severance pay (“Severance Pay”) consisting of twelve months of Executive’s annualized
base salary of Four Hundred Twenty-Five Thousand dollars ($425,000), representing the twelve-month period from the Termination
Date to and including January 31, 2013 (the “Severance Pay Period”). The Severance Pay shall be paid in lump sum on
or about the fifteenth business day following the Termination Date, provided that the Company is not obligated to pay any Severance
Pay before this General Release becomes effective. The Severance Pay shall be paid less applicable withholdings and deductions
as required by law. The Executive acknowledges and agrees that the Severance Pay: (i) represents payments to which the Executive
would not otherwise be entitled to but for the Executive’s agreement to and execution of this General Release; (ii) is in
full and final discharge of any and all liabilities and obligations of the “Company Releasees” (as defined in Section
6 below) to the Executive, including with respect to termination benefits, severance pay, salary, wages, bonuses, incentive compensation,
and all other compensation, employee benefits and otherwise, and (iii) exceeds any such payment, benefit, or other thing of value
to which the Executive might otherwise be entitled under any policy, procedure or plan of any of the Company Releasees and/or any
other agreement between the Executive and any of the Company Releasees.

    	 

    	 

    
3.Restricted
Stock and Stock Options. The Executive acknowledges and agrees that all shares of restricted stock and options that the Executive
holds to purchase shares of the Company’s common stock pursuant to the IntraLinks Holdings, Inc. 2010 Equity Incentive Plan
or any applicable predecessor plan that are not vested as of the Termination Date shall lapse on that date and will not be releasable
or exercisable. The release of any restricted shares and the exercise of any stock options shall be subject to the terms of the
IntraLinks Holdings, Inc. 2010 Equity Incentive Plan, or applicable predecessor plan. This Section 3 is not intended to modify
in any respect the post-separation rights to which the Executive would otherwise be entitled if the Executive were not to agree
to this General Release or the terms governing restricted stock or stock options. Notwithstanding the foregoing, in consideration
of the Executive’s agreement to the terms and conditions contained in this General Release, the Company agrees to
accelerate and fully vest as of January 31, 2012 the portion of Executive’s stock option award granted on February
26, 2010 that is not vested as of the Termination Date (221,429 options to purchase the Company’s common stock at a purchase
price of $6.76) and to extend the exercise period of such stock option and any other option awards that are vested as of the Termination
Date (the “Equity Severance Benefit”) until the close of the New York Stock Exchange on January 31, 2013 (the “Exercise
Deadline”). Any stock options underlying the Equity Severance Benefit that are not exercised by the Exercise Deadline shall
be forfeited and cancelled. The Executive acknowledges and agrees that the Equity Severance Benefit: (i) is a benefit to which
the Executive would not otherwise be entitled to but for the Executive’s agreement to and execution of this General Release;
(ii) is in full and final discharge of any and all liabilities and obligations of the “Company Releasees” (as defined
in Section 6 below) to the Executive, including with respect to termination benefits, severance pay, salary, wages, bonuses, incentive
compensation, and all other compensation, employee benefits and otherwise, and (iii) exceeds any such payment, benefit, or other
thing of value to which the Executive might otherwise be entitled under any policy, procedure or plan of any of the Company Releasees
and/or any other agreement between the Executive and any of the Company Releasees. The Executive acknowledges and agrees that he
will continue to be subject to the IntraLinks Holdings, Inc. Statement of Company Policy on Insider Trading and Disclosure (the
“Insider Trading Policy”).

4.Severance
Health Benefit. The Executive’s rights and obligations under COBRA are explained in a separate letter describing medical
and dental insurance continuation rights under COBRA. To continue the Executive’s medical and dental insurance coverage,
the Executive must elect COBRA continuation coverage. If the Executive elects COBRA continuation coverage and provided that the
Executive (and the Executive’s eligible beneficiaries) remains eligible for COBRA continuation coverage, the Company shall
reimburse the Executive for medical and dental insurance COBRA continuation premiums for coverage of the Executive (and the Executive’s
eligible beneficiaries) to the same extent as if the Executive had remained employed to the end of the Severance Pay Period on
January 31st 2013 (the “Severance Health Benefit”). The Executive will be responsible for the remaining
portion of such coverage as if the Executive remained employed. If the Executive elects COBRA continuation coverage, the Executive
may continue coverage for the Executive’s own benefit and for the benefit of any beneficiaries after the end of the Severance
Pay Period at the Executive’s own expense for the remainder of the COBRA period, to the extent the Executive (and the Executive’s
eligible beneficiaries) remain eligible. The Executive acknowledges and agrees that the Severance Health Benefit: (i) is a benefit
to which the Executive would not otherwise be entitled to but for the Executive’s agreement to and execution of this General
Release; (ii) is in full and final discharge of any and all liabilities and obligations of the “Company Releasees”
(as defined in Section 6 below) to the Executive, including with respect to termination benefits, severance pay, salary, wages,
bonuses, incentive compensation, and all other compensation, employee benefits and otherwise, and (iii) exceeds any such payment,
benefit, or other thing of value to which the Executive might otherwise be entitled under any policy, procedure or plan of any
of the Company Releasees and/or any other agreement between the Executive and any of the Company Releasees.

    	2

    	 

    
5.Indemnification
Agreement and Liability Coverage. Company agrees that notwithstanding anything contained herein to the contrary, the indemnification
agreement dated November 29th, 2011 between Company and Executive (the “Indemnification Agreement”) shall
remain in full force and effect and Executive shall continue to be entitled to all of the benefits of Indemnification Agreement
including, but not limited to, any rights thereunder to any Officers and Director’s Liability Insurance policy, whether through
an independent or captive insurer or rights under or to any indemnification trust, and any continuing rights for indemnification
under the Company’s charter or bylaws in effect as of the date hereof. Company agrees that should a conflict or potential
conflict arise between the Company, its officers or its directors and the Executive as the result of a class action lawsuit(s)
where the Executive is named as a defendant, or any other legal matter or action where the Executive is named as a defendant, or
threatened to be named as a party, that the Executive can seek legal counsel independent of the Company’s counsel in accordance
with the Indemnification Agreement. All costs, fees and expenses associated with obtaining independent legal counsel and continuing
to pay for such counsel shall be advanced and paid by the Company as outlined in the Indemnification Agreement, including and not
limited to the benefits of the Company’s Officer’s and Director’s Liability Insurance policy.

6.General
Release. For good and valuable consideration, including but not limited to the Severance Pay set forth in Section 2 of this
General Release, the Equity Severance Benefit set forth in Section 3 of this General Release, and the Severance Health Benefit
set forth in Section 4 of this General Release, the Executive releases, discharges, and promises not to sue the Company, any of
its and their parents, subsidiaries, affiliates, and related entities, and/or any and all of its and their current or former directors,
officers, members, employees, attorneys, representatives, insurers, agents, heirs, successors, and assigns (individually and collectively
the “Company Releasees”), from and with respect to any and all claims, actions, suits, liabilities, debts, controversies,
contracts, agreements, obligations, damages, judgments, causes of action, and contingencies whatsoever, including attorneys’
fees and costs, in law or in equity, known or unknown, suspected or unsuspected, asserted or unasserted, which against the Company
Releasees, the Executive and the Executive’s respective heirs, administrators, executors, successors, assigns, attorneys,
and affiliates (individually and collectively the “Executive Releasors”) ever had, now has, or hereafter can, shall,
or may have for, upon, or by reason of any matter, cause, or thing whatsoever from the beginning of the world through the date
the Executive executes this General Release (individually and collectively, “Claims”). This includes, without limitation,
(i) any Claims in connection with or arising from the Executive’s employment by the Company or the separation or end of such
employment; (ii) any Claims for compensation, salary, bonus, deferred compensation, commissions, carried interest, incentive compensation
or similar benefit, equity compensation, stock options, severance pay, pension, vacation pay, life insurance, disability benefits,
health or medical insurance, or any other fringe benefit; (iii) any Claims under any federal, state, or local law, regulation,
or ordinance, including without limitation any Claims under Title VII of the Civil Rights Act of 1964, the Age Discrimination in
Employment Act, the Americans with Disabilities Act, the Employee Retirement Income Security Act, the Fair Labor Standards Act,
the Family Medical Leave Act, the New York State Human Rights Law, the New York City Human Rights Law, the New York Labor Law and
the Massachusetts General Laws; (iv) any Claims under common law including, without limitation, any Claim for tort, breach of contract
(express or implied, written or oral), quasi contract, or wrongful or constructive discharge; and (v) any Claims for compensatory
damages, punitive damages, or attorneys’ fees, costs, disbursements and the like. The Executive represents that the Executive
has not assigned any Claim released herein. The Executive intends this release to be a general release of any and all Claims to
the fullest extent permissible by law, excluding Severance Pay set forth in Section 2 of this General Release, the Equity Severance
Benefit set forth in Section 3 of this General Release, the Severance Health Benefit set forth in Section 4 of this General Release
and the continued benefits of the Indemnification Agreement as referenced in Section 5 of this General Release, and the right to
enforce this General Release, none of which are released Claims hereunder.

    	3

    	 

    
7.Indemnification
for Claims. The Executive represents and warrants that neither the Executive nor any other Executive Releasor has previously
filed, and to the maximum extent permitted by law agrees that neither Executive nor any other Executive Releasor will file, a complaint,
charge or lawsuit against any of the Company Releasees regarding any of the Claims released herein, but may defend against any
such complaint, charge or lawsuit by a Company Releasee, including, without limitation, by asserting counterclaims, third party
claims and cross-claims. If, notwithstanding this representation and warranty, an Executive Releasor has filed or files such a
complaint, charge or lawsuit, the Executive agrees that the Executive shall cause such complaint, charge or lawsuit to be dismissed
with prejudice and shall pay any and all costs required in obtaining such dismissal of such complaint, charge or lawsuit, including
without limitation the attorneys’ fees of any party against whom an Executive Releasor has filed such a complaint, charge,
or lawsuit. The immediately preceding sentence shall not apply, however, to a Claim of age discrimination under the Age Discrimination
in Employment Act. Notwithstanding any other language in this General Release, the parties understand that this General Release
does not prohibit the Executive from filing an administrative charge with the Equal Employment Opportunity Commission or similar
administrative agency. The Executive, however, waives any right to monetary or other recovery should any federal, state or local
administrative agency pursue claims on the Executive’s behalf arising out of or relating to the Executive’s employment
with the Company or the separation of the Executive’s employment with the Company.

8.Tax
Treatment. The Company shall undertake to make deductions, withholdings and tax reports with respect to payments and benefits
under this General Release to the extent that it reasonably and in good faith determines that it is required to make such deductions,
withholdings and tax reports. Payments under this General Release shall be in amounts net of any such deductions or withholdings.
Nothing in this General Release shall be construed to require the Company to make any payments to compensate the Executive for
any adverse tax effect associated with any payments or benefits or for any deduction or withholding from any payment or benefit.

    	4

    	 

    
9.Return
of Property. The Executive hereby represents and warrants that, prior to the Termination Date, the Executive has returned,
or will return, to the Company all Company property, including, without limitation, cell phones, computer equipment, software,
keys and access cards, credit cards, files and any documents (including computerized data and any copies made of any computerized
data or software) containing information concerning the Company, its business or its business relationships (in the latter two
cases, actual or prospective). The Executive further represents and warrants that, prior to the Termination Date, the Executive
has deleted, or will delete, any duplicates of files or documents that may contain Company information from any computer or other
device that remains the Executive’s property after the Termination Date. In the event that the Executive discovers that the
Executive continues to retain any such property, the Executive shall return it to the Company immediately.

10.Confidential
Information. The Executive understands and agrees that the Executive has been employed in a position of confidence and trust
and has had access to information concerning the Company that the Company treats as confidential and the disclosure of which could
negatively affect the Company’s interests (“Confidential Information”). Confidential Information includes, without
limitation, confidential financial information; business forecasts; inventions; improvements and other intellectual property; trade
secrets; know-how; designs, processes or formulae; confidential software; marketing or sales information or plans; customer lists;
and business plans, prospects and opportunities. The Executive agrees and warrants that the Executive shall not use or disclose
any Confidential Information at any time without the prior written consent of the Company.

11.Non-Disparagement.
The Executive agrees that the Executive shall not make any statement, orally or in writing, nor take any action, that (a) in any
way could disparage the Company or any of the Company Releasees, or which foreseeably could harm the reputation or goodwill of
those persons or entities, or (b) in any way directly or indirectly, could knowingly cause or encourage or condone the making of
such statements or the taking of such actions by anyone else. In turn, the Company agrees that the Company shall not make any statement,
orally or in writing, nor take any action, that in any way could disparage the Executive, or which foreseeably could harm the reputation
or goodwill of the Executive. Nothing in this Section 12 shall prevent the Executive from testifying truthfully if required by
legal process to testify.

12.Future
Cooperation. The Executive agrees to cooperate reasonably with the Company and all of its affiliates (including its and their
outside counsel) in connection with the contemplation, prosecution and defense of all phases of existing, past and future litigation
about which the Company believes the Executive may have knowledge or information. The Executive further agrees to be available
at mutually convenient times during and outside of regular business hours as reasonably deemed necessary by the Company’s
counsel. The Executive agrees to appear without the necessity of a subpoena to testify truthfully in any legal proceedings in which
the Company calls the Executive as a witness. The Company shall also reimburse the Executive for any pre-approved reasonable business
travel expenses that the Executive incurs on the Company’s behalf as a result of the Executive’s litigation cooperation,
after receipt of appropriate documentation consistent with the Company’s business expense reimbursement policy.

    	5

    	 

    
13.Suspension
or Termination of Payments. In the event that the Executive fails to comply with any of the Executive’s obligations under
this General Release, in addition to any other legal or equitable remedies it may have for such breach the Company shall have the
right to terminate or suspend its payments to the Executive under this General Release. The termination or suspension of such payments
in the event of such breach by the Executive will not affect the Executive’s continuing obligations under this General Release.
Notwithstanding the foregoing, this provision shall not apply to the extent that the Executive’s breach of this General Release
consists of initiating a legal action in which the Executive contends that the release set forth in Section 6 is invalid,
in whole or in part, due to the provisions of 29 U.S.C. § 626(f).

14.Sections
of the Employment Agreement, Stock and Option Agreements and Insider Trading Policy Still in Effect. The Executive is a party
to the Employment Agreement, certain restricted stock and stock option agreements under the TA Indigo Holding Corporation 2007
Stock Option and Grant Plan, the IntraLinks Holdings, Inc. 2007 Stock Option and Grant Plan, the IntraLinks Holdings, Inc. 2010
Equity Incentive Plan (collectively, as modified herein, the “Stock and Option Agreements”) and is subject to the Insider
Trading Policy. The Executive acknowledges that certain of the Executive’s obligations under the Employment Agreement, the
Stock and Option Agreements and Insider Trading Policy were intended to, and do in fact, survive the termination of the Executive’s
employment with the Company. The Executive hereby reaffirms the Executive’s obligations existing under the Employment Agreement,
including with respect to noncompetition, nonsolicitation and nondisclosure as set forth in Section 7 thereof, the Stock and Option
Agreements and the Insider Trading Policy all of which are incorporated by reference into this Section 14 and shall remain in full
force and effect. The Executive further agrees and acknowledges that nothing contained in this General Release shall be construed
to relieve the Executive of such ongoing obligations including, without limitation, those set forth in Section 7 of the Employment
Agreement. The Executive further acknowledges that the severance payments and benefits provided for in Sections 2, 3 and 4 of this
General Release are in lieu of any termination benefits under the Employment Agreement or any severance policy of the Company,
are contingent upon the Executive’s continued compliance with any ongoing obligations under the Employment Agreement, the
Stock and Option Agreements and the Insider Trading Policy and that such payments and benefits shall cease in the event the Executive
breaches any of the Executive’s contractual obligations set forth in the Employment Agreement, the Stock and Option Agreements
or the Insider Trading Policy.

15.Waiver
or Modification. A waiver or modification by the Company of any condition, obligation or breach hereunder or hereof shall not
be construed as a waiver or modification of any other condition, obligation or breach, nor shall a waiver or modification by the
Company granted on one occasion be construed as applying to any other occasion. No waiver or modification shall be binding unless
in writing and signed by the party waiving the condition, obligation or breach. For purposes of this Section 15, any waiver by
the Company must be signed by the Chairperson of the Board of the Company.

    	6

    	 

    
16.Controlling
Law. This General Release shall be construed in accordance with and governed by the laws of the State of New York, without
regard to principles of conflict of laws.

17.Jurisdiction.
The Executive and the Company hereby agree that the New York State Supreme Court and the United States District Court for the Southern
District of New York shall have the exclusive jurisdiction to consider any matters related to this General Release, including without
limitation any claim for violation of this General Release. With respect to any such court action, the Executive (i) submits to
the jurisdiction of such courts, (ii) consents to service of process, and (iii) waives any other requirement (whether imposed by
statute, rule of court or otherwise) with respect to personal jurisdiction or venue.

18.Entire
Agreement. This General Release, together with the Stock and Option Agreements, Insider Trading Policy and the surviving provisions
of the Employment Agreement, constitutes and contains the complete understanding of the Executive and the Company with respect
to the subject matter addressed in this General Release, and supersedes and replaces all prior negotiations and all agreements,
whether written or oral, concerning the subject matter of this General Release. This is an integrated document.

19.Severability;
Injunctive Relief. If any portion or provision of this General Release shall to any extent be declared illegal or unenforceable
by a court or arbitrator of competent jurisdiction, then the remainder of this General Release, or the application of such portion
or provision in circumstances other than those as to which it is so declared illegal or unenforceable, shall not be affected thereby,
and each portion and provision of this General Release shall be valid and enforceable to the fullest extent permitted by law. In
the event that any portion or provision of this General Release is determined by a court or arbitrator of competent jurisdiction
to be unenforceable by reason of excessive scope as to geographic, temporal or functional coverage, such provision will be deemed
to extend only over the maximum geographic, temporal and functional scope as to which it may be enforceable.
Executive agrees that it would be difficult to measure any harm caused to the Company that might result from any breach by Executive
of Sections 9-12 and Section 14 of this General Release, including any of the Executive’s continuing obligations set forth
in the Employee Agreement, that money damages would be an inadequate remedy for any such breach and that if he breaches, or proposes
to breach, any portion of such provisions the Company shall be entitled, in addition to all other remedies it may have, to an injunction
or other appropriate equitable relief to restrain any such breach, without showing or proving any actual damage to the Company
and without the necessity of posting a bond. 

20.Counterpart
and Facsimile Signatures. The parties agree that facsimile or PDF signatures of this General Release shall be treated the same
as an original signature and further agree that the General Release may be executed in counterparts.

21.Older
Worker Benefit Protection Act Disclosure; Representations, Warranties and Signature. The Executive recognizes that as part
of the Executive’s agreement to release any and all Claims against the Company and the other Company Releasees, the Executive
is releasing Claims for age discrimination under the Age Discrimination in Employment Act, although the Executive has never asserted
such Claims. Accordingly, under the terms of the Older Worker Benefit Protection Act, the Executive has a right to reflect upon
this General Release for a period of up to twenty-one (21) days before executing it (the “Review Period”), and the
Executive has an additional period of seven (7) days after executing this General Release to revoke it (the “Revocation Period”).
If the Executive elects to revoke this General Release, the Executive must provide written notice of such revocation to the Company
(to the attention of:  General Counsel, IntraLinks Holdings, Inc., 150 East 42nd Street, 8th Fl, New York, NY 10017) by
no later than the end of the last day of the Revocation Period. If the last day of the Review Period and/or Revocation Period falls
on a Saturday, Sunday or holiday, then the last day of the Review Period and/or Revocation Period (as applicable) shall be deemed
to be the next business day after such Saturday, Sunday or holiday. Unless properly revoked prior to the expiration of the Revocation
Period, this General Release shall become effective immediately on the day after the last day of the Revocation Period (the “Effective
Date”).

    	7

    	 

    
22.Effect
of Non-Acceptance or Revocation of this General Release. The Executive agrees that if the Executive does not return a signed
and dated copy of this General Release to the Company (to the attention of:  General Counsel, IntraLinks Holdings, Inc.,
150 East 42nd Street, 8th Fl, New York, NY 10017) by on or before the twenty-first (21st) day after the Executive’s receipt
of this General Release (i.e., by the end of the Review Period) or if the Executive properly revokes this General Release prior
to the end of the Revocation Period, then the provisions of this General Release shall be null and void and of no further force
and effect.

23.Knowing
and Voluntary Acceptance and Agreement. By the Executive’s signature below, the Executive represents and warrants: (i)
that the Executive hereby is advised in writing, and that the Executive has been so advised, to consult with an attorney of the
Executive’s own choosing in connection with this General Release; (ii) that the Executive has been given a reasonable amount
of time to consider this General Release of not less than twenty-one (21) days; (iii) that the Executive fully understands the
significance of the terms and conditions of this General Release and has discussed them with the Executive’s independent
legal counsel, or has had a reasonable opportunity to have done so; (iv) that the Executive agrees to all the terms and conditions
of this General Release without any coercion; (v) that the Executive is signing this General Release voluntarily and of the Executive’s
own free will, with the full understanding of its legal consequences, and with the intent to be bound hereby; and (vi) that if
the Executive signs this General Release during the Review Period prior to the twenty-first (21st) day thereof, the Executive is
voluntarily and knowingly waiving the remainder of the Executive’s twenty-one (21) day period to review and consider this
General Release.

IN WITNESS WHEREOF,
the parties to this General Release, intending to be legally bound, have caused this General Release to be executed as of the date
set forth above.

 

	 	
        EXECUTIVE
	 	 	INTRALINKS HOLDINGS, INC.
	 	 	 	 	 
	 	 	 	 	 
	By:	
        /s/ J. Andrew Damico
        J. Andrew Damico
	 	By:	
        /s/ Ronald W. Hovsepian

        Ronald W. Hovsepian 

        President and Chief Executive Officer

	 	 	 	 	 

 

    	8

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00198-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00198-of-00352.parquet"}]]