Document:

Exhibit 10.3

    

     

    
      PORTIONS OF THIS EXHIBIT HAVE BEEN OMITTED BECAUSE SUCH PORTIONS ARE BOTH NOT MATERIAL AND WOULD BE COMPETITIVELY HARMFUL IF PUBLICLY DISCLOSED. THE OMISSIONS HAVE BEEN
        INDICATED BY ASTERISKS (“[***]”).

      

      

      

      

    

     

    DATED 6th OCTOBER, 2017

     

    PPL SHIPYARD PTE LTD

     

    and

     

    BORR DRILLING LIMITED.

     

    	
            MASTER AGREEMENT

          

    
      
        
 

    

    
    THIS AGREEMENT is made the 6th day of October 2017

     

    BETWEEN:

     

    
      	(1)	
              PPL SHIPYARD PTE. LTD., a corporation incorporated under the laws of Singapore and having its registered office at 21 Pandan Road Singapore 609273 (the “Seller”);
                and

            

    

     

    
      	(2)	
              BORR DRILLING LIMITED, a company incorporated under the laws of Bermuda and having its office at Thistle House, 4 Burnaby Street, Hamilton HM11 Bermuda (“Buyer
                  Parent”).

            

    

     

    (Each of the Seller and the Buyer Parent are hereinafter referred to individually as a “Party” and, collectively, the “Parties”.)

     

    WHEREAS:

     

    
      	A.	
              The Parties entered into a Letter of Agreement dated 6 September 2017 in terms of which they agreed the main terms on which the Seller would sell, and the Buyer Parent would nominate wholly-owned subsidiaries (each a “Buyer” and together the “Buyers”) to acquire, nine (9) Pacific Class® 400 jack-up drilling rigs, listed in Schedule 1 hereto (each a “Rig” and together the “Rigs”).

            

    

     

    
      	B.	
              Six of the Rigs are complete (each a “Completed Rig” and together the “Completed Rigs”) with one, namely Hull No. 2053, pending issuance of classification
                certificate and three of the Rigs are under construction (each a “Construction Rig” and together the “Construction Rigs”).

            

    

     

    
      	C.	
              The Parties have agreed to enter into this Agreement to record the terms and conditions on which they and the Buyers will enter into definitive sale and purchase agreements for the Rigs.

            

    

     

    NOW THEREFORE, it is hereby agreed as follows:

     

    
      	1.	
              DEFINITIONS

            

    

     

    
      	1.1	
              For the purpose of this Agreement, terms defined in the Recitals and elsewhere in this Agreement have the meanings set out therein, and the following words and expressions shall have the meanings ascribed to them
                below:

            

    

     

    “Business Day” means any day (which is not a Saturday or a Sunday or any public holiday) on which
      banks are required to be open in London, Oslo, Singapore and New York.

     

    “Confidential Information” has the meaning given to it in Clause 11.

     

    “Construction Agreement” refers to the rig construction agreement for the construction and
      delivery in respect of the sale and purchase of each of the Construction Rigs, to be substantially in the form attached hereto.

     

    “Delivery Date” means the date for delivery of a rig as set out in the third column of Schedule 1
      or such other delivery date as agreed by the Seller, the relevant Buyer and the Buyer Parent in writing in respect of a Rig.

    
      Page 1

      
        
 

    

    “Lien” means any lien, mortgage, trust, encumbrance, pledge, charge, lease, interest, easement,
      servitude, right of others, transfer or security interest of any kind, including those arising under any securitisation or any conditional sale or other title retention agreement, and any other right or arrangement with any creditor to have its claim
      satisfied out of any property or assets with the proceeds therefrom, prior to the general creditors of the owner thereof (whether or not filed, recorded, perfected or effective).

     

    “Losses” means any and all claims, losses, damages, liabilities, costs and expenses (including
      reasonable disbursements and legal fees) that are imposed upon or incurred by any Person entitled to be indemnified under this Agreement.

     

    “Original Buyer” means a person who was party as “buyer” to an Original Contract, either as the
      initial contracting buyer or buyer substituted by way of nomination or novation.

     

    “Original Contract” means a contract for the design, construction and sale of a Rig by the Seller
      for an Original Buyer.

     

    “SPA” refers to the sale and purchase agreement in respect of the sale and purchase of each of
      the Completed Rigs, to be substantially in the form attached hereto.

     

    “Tax” includes (without limitation) all taxes, levies, duties, imposts, charges and withholdings
      of any nature whatsoever, as well as any transfer, recording, registration and other fees, in each case in any jurisdiction and together with all penalties, charges and interest relating to any of them or to any failure to file any return required
      for the purposes of any of them and “Taxes” and “Taxation” shall be construed accordingly;

     

    
      	2.	
              EFFECTIVE DATE OF AGREEMENT

            

    

     

    
      	2.1	
              This Agreement shall come into effect on the date of execution by both Parties but the obligations and rights of the Parties hereunder shall commence on the date on which the following conditions having been met
                (the “Effective Date”):

            

    

     

    
      	

            	(a)	
              the Buyer Parent completing, and confirming its satisfaction with, its due diligence review of the Rigs, the Specifications, class and other documentation specified by the Buyer Parent as being subject to due
                diligence review;

            

    

     

    
      	

            	(b)	
              the Buyer Parent confirms to the Seller that the Buyer Parent has raised sufficient new equity;

            

    

     

    
      	

            	(c)	
              the board of each of the Parties unconditionally approves this Master Agreement, the SPAs and the Construction Agreements;

            

    

     

    
      	

            	(d)	
              this Master Agreement, the SPAs and the Construction Agreements are duly executed by authorised signatories of both Parties and the Buyers.

            

    

     

    
      	2.2	
              If the Effective Date does not occur by 23:59 hours in Oslo on 18 October 2017 this Agreement shall automatically terminate on 19 October 2017 (the “Termination Date”) and
                neither Party (nor any Buyer) shall have any obligation or liability to the other except under Clause 11 (Press Release and Confidential Information).

            

    

    
      Page 2

      
        
 

    

    
      	3.	
              BUYERS

            

    

     

    
      	3.1	
              The Buyer Parent has incorporated or shall incorporate wholly-owned single purpose Marshall Islands entities to be the Buyers of the Rigs and will nominate one such Buyer for each Rig.

            

    

     

    
      	3.2	
              The SPAs and the Construction Agreements shall be executed on or by 10 October 2017, or such later date as mutually agreed by the Parties.

            

    

     

    
      	3.3	
              Each of the SPAs and the Construction Agreements shall be standalone agreements independent of any other SPA or Construction Agreement, and shall bind the Seller, the Buyer and the Buyer Parent (to the extent that
                they are providing the parent guarantee therefor). The Parties’ respective obligations and liabilities in each of the agreement shall be limited to that stated therein, and there shall not be any cross liability or overlap of obligations
                between the various agreements.

            

    

     

    
      	4.	
              PRICE AND PAYMENT TERMS

            

    

     

    
      	4.1	
              The total purchase price for the Rigs shall be United States Dollars One Billion Two Hundred and Fifty-Five Million Five Hundred Thousand (US$1,255,500,000), and the price per Rig as set out in Schedule 1 (the “Rig Purchase Price”).

            

    

     

    
      	4.2	
              A first instalment of the Rig Purchase Price for each Rig in the amount set out in Schedule 1 shall be payable not later than fifteen (15) Business Days from the Effective Date (the “First Instalment”).

            

    

     

    
      	4.3	
              If a Rig is delivered pursuant to a SPA or Construction Contract, the balance of the Rig Purchase Price for each Rig shall be due by the relevant Buyer when its Rig is delivered and shall be settled by way of an
                interest-bearing secured seller’s credit in the amount set out in Schedule 1 payable [***] the date falling 60 months from the date that Buyer actually takes delivery of its Rig (the “Seller’s Credit”).
                The terms of the Seller’s Credit are to be set out in each of the SPAs and Construction Contracts.

            

    

     

    
      	4.4	
              For the purpose of clarification and avoidance of doubt, in the event the Buyer takes delivery of the Rig later than the Delivery Date, and such delay in taking delivery is not due to any delay on the part of
                Seller, the accrual of the interest on the Balance Payment shall commence on the Delivery Date. In the event that a Buyer takes delivery earlier than the Delivery Date, the Balance Payment becomes due and interest starts to accrue on the
                actual delivery date.

            

    

     

    
      	4.5	
              Each Buyer shall during the period from the Effective Date up to the date on which the last Rig is delivered under this Agreement, place orders worth not less than US$[***] for equipment and spares for its Rig by
                executing and issuing purchase order forms to the Seller. Each Buyer shall be liable to make an additional payment of [***]% on the value of such purchase orders as administrative charges. If the total value of a Buyer’s orders within this
                period is less than US$[***], Buyer shall pay to Seller [***]% of the shortfall. Each Buyer shall make payment on its orders within 30 days from the date of Seller’s Invoice.

            

    

    
      Page 3

      
        
 

    

    
      	5.	
              SECURITY

            

    

     

    
      	5.1	
              Each Buyer’s obligation to pay the part of the Seller’s Credit and the back end fee (as provided in Clause 6.1(A) and (B) herein) which they have to pay under the terms of the SPA or Construction Agreement to
                which they are a party, shall be secured by a parent guarantee from the Buyer Parent.

            

    

     

    The Seller’s obligation to refund each First Instalment and any and all other amounts in accordance with the terms of the SPA or the
      Construction Contract shall be secured by a parent guarantee.

     

    
      	5.2	
              Each Buyer’s obligation to repay its Seller’s Credit and each Buyer’s obligation to pay the back end fee (as provided in Clause 6.1(A) and (B) herein) shall be secured by a first priority mortgage over its Rig and
                a first party assignment of the insurances and requisition compensation of that Rig (each a “Mortgage”).

            

    

     

    
      	5.3	
              Seller shall have the right to assign its rights to receive repayment of the Seller’s Credit from the Buyer and its rights to receive payment of the back end fee as stated at Clause 6.1(A) and (B) from the Buyer
                and its rights to, and interests in, the security in its favour as provided in Clause 5 herein to any third party including any financial institution.

            

    

     

    
      	6.	
              BACK END FEE

            

    

     

    
      	6.1	
              The Parties have agreed that the Seller shall be entitled to a market based back end fee as follows:

            

    

     

    
      	

            	(A)	
              In respect of each Rig, a definite fixed sum of United States Dollars [***] Million [***].

            

    

     

    
      	

            	(B)	
              Additionally, in respect of each Rig, Buyer shall pay to Seller an amount to reflect the uplift in value of the Rig at the time when Buyer pays to Seller the Seller’s Credit.

            

    

     

    The amount to reflect the uplift in value of the Rig shall be calculated as follows:

     

    An amount equal to 25% of the increase in value of the Rig obtained from the difference between:

     

    
      	

            	(1)	
              the average of 3 independent broker quotes for the value of the Rig at the time of Buyer’s payment of the Seller’s Credit, and

            

    

     

    
      	

            	(2)	
              the Rig Purchase Price stated hereinabove.

            

    

     

    Less

     

    
      	

            	(a)	
              [***]% per annum of the First Instalment amount for the Rig, calculated from the date of delivery of the Rig by the Seller to the Buyer until the date the Buyer pays the Seller the Seller’s Credit; and

            

    

     

    
      	

            	(b)	
              an amount equal to the interest accrued and/or paid by Buyer to Seller in respect of the Seller’s Credit.

            

    

     

    In the event that the average of the 3 independent broker quotes is lower than the Rig Purchase Price, or if the amount to reflect the uplift in value of
      the Rig as calculated above results in a negative figure, then no amount under this sub-clause (B) will be payable by either Party to the other.

    
      Page 4

      
        
 

    

    The amounts in (A) and (B) above in respect of each Rig shall be payable by Buyer to Seller together with the repayment of the Seller’s
      Credit.

     

    
      	7.	
              DELIVERY AND TITLE

            

    

     

    
      	7.1	
              Delivery of the Rigs shall take place on the Delivery Date set out in Schedule 1 in accordance with the terms of the respective SPAs and Construction Agreements, and shall be subject to the terms set out therein.

            

    

     

    
      	7.2	
              Risk and title (free of Liens other than a Mortgage) to a Rig shall pass to the Buyer at the time and place recorded in a protocol of delivery executed by both the Seller and the relevant Buyer on the Delivery
                Date for that Rig.

            

    

     

    
      	7.3	
              Seller has obtained ABS Class Certificate for Rigs 1, 2, 3, 4 & 6 and these Rigs are presently in lay-up mode at Seller’s yard. Buyer accept Rigs 1, 2, 3, 4 & 6 as per the inspection at the signing of this
                Agreement. Rigs 1, 2, 3, 4 & 6 will be delivered and taken over in substantially the same condition as at the time of inspection at the signing of this Agreement.

            

    

     

    ABS has issued a Statement of Fact dated 20 October 2016 for Rig 5 confirming that upon completion of remaining minor scope of work, ABS
      will issue an interim class certificate for the Rig. ABS Statement of Fact is attached hereto as Schedule 2. Buyer shall accept the condition of Rig 5 when the said Rig have been classed by the ABS Certification Society as evidenced by the attainment
      by Seller of the interim classification certificate.

     

    In the period between the date of signing the SPAs and the Delivery Date, the Rigs will be maintained by the Seller in accordance with
      the Seller’s preservation regime at the time of inspection.

     

    Buyer shall accept the condition of Rigs 7 to 9 when the said Rigs have been classed by the ABS Classification Society as evidenced by
      the attainment by Seller of the interim classification certificate.

     

    
      	7.4	
              In the event Buyer takes delivery of any of the Rigs later than the Delivery Dates as set out in Schedule 1 hereto, and such delay in taking delivery is not due to any delay on the part of Seller, Buyer shall
                compensate Seller for the additional costs to keep the Rigs at its yard, including but not limited to the costs of preservation, maintenance, storage and insurance for the Rigs.

            

    

     

    
      	8.	
              REPRESENTATIONS AND WARRANTIES

            

    

     

    
      	8.1	
              The Seller hereby represents and warrants to the Buyer on the date hereof in the terms of the representations and warranties set out below:

            

    

     

    
      	

            	(a)	
              it is a company duly organised and validly existing under Applicable Law, and has full corporate power and authority to conduct its business as it is presently being conducted and it has all necessary corporate
                authority and has taken all corporate action necessary to enter into this Agreement, the SPAs and the Construction Contracts and to consummate the transactions contemplated hereby and to perform its obligations hereunder.

            

    

     

    
      Page 5

      
        
 

    

    
      	

            	(b)	
              neither the execution and delivery of this Agreement, the SPAs or the Construction Contracts (or any of them) by the Seller nor the performance by the Seller of its obligations hereunder will result in (i) a
                violation of the memorandum or articles of association of the Seller, or (ii) a violation by the Seller of any applicable law;

            

    

     

    
      	

            	(c)	
              no consent, approval or authorisation of, or declaration, filing or registration with, any governmental authority, or any other person, is required to be made or obtained by the Seller in connection with the
                execution, delivery and performance of this Agreement, the SPAs or the Construction Contracts (or any of them) and the performance of its obligations hereunder or thereunder; and

            

    

     

    
      	

            	(d)	
              each Original Contract has been duly terminated, and no claims have been asserted or threated by any Original Buyer against the Seller or any of the Rigs.

            

    

     

    
      	8.2	
              The Buyer Parent hereby represents and warrants to the Seller on the date hereof in the terms of the representations and warranties set out below:

            

    

     

    
      	

            	(a)	
              It is a corporation duly organised and validly existing under applicable law and has full corporate power and authority to conduct its business as it is presently being conducted and has all necessary corporate
                authority and has taken all corporate action necessary to enter into this Agreement, to consummate the transactions contemplated hereby and to perform its obligations hereunder;

            

    

     

    
      	

            	(b)	
              neither the execution and delivery of this Agreement, the SPAs or the Construction Contracts (or any of them) by the Buyer Parent and/or the Buyers nor the performance by the Buyer Parent or a Buyer of its
                respective obligations hereunder or thereunder will result in (i) a violation of the constitutional documents of the Buyer Parent or any Buyer or (ii) a violation by the Buyer Parent or a Buyer of any applicable law; and

            

    

     

    
      	

            	(c)	
              no consent, approval or authorisation of, or declaration, filing or registration with, any governmental authority, or any other person, is required to be made or obtained by the Buyer Parent or a Buyer in
                connection with the execution, delivery and performance of this Agreement, the SPAs or Construction Contracts or the performance of its obligations hereunder or thereunder.

            

    

     

    
      	9.	
              INDEMNIFICATION

            

    

     

    
      	9.1	
              The Seller irrevocably and unconditionally undertakes to hold harmless (on a full indemnity basis) the Buyer Parent and each Buyer and its and their respective directors, officers, employees and agents, from and
                against any Losses arising from or by reason of or related to any claim by an Original Buyer against a Buyer, the Parent Buyer or any Rig.

            

    

    
      Page 6

      
        
 

    

    
      	10.	
              EXPENSES

            

    

     

    
      	10.1	
              Except as is otherwise specifically provided in this Agreement, and without prejudice to any claims for damages, each Party shall pay its own costs and expenses in connection with this Agreement, the SPAs and the
                Construction Agreements and the transactions contemplated hereby, including (without limitation) all legal fees and disbursements, accounting fees and other expenses and any Taxes thereon or arising in connection therewith.

            

    

     

    
      	10.2	
              The Seller shall be liable for all costs relating the registration of the Mortgage.

            

    

     

    
      	11.	
              PRESS RELEASE AND CONFIDENTIAL INFORMATION

            

    

     

    
      	11.1	
              The Parties shall agree the terms of, and timing of, any and all press releases or other announcements of this Agreement and neither Party shall make any public announcement without the prior written consent of
                the other Party, unless so required by applicable law or the requirements of a securities exchange or government authority.

            

    

     

    
      	11.2	
              The Parties shall, and the Buyer Parent shall procure that each Buyer shall, treat as confidential (and as “Confidential Information” for the purposes of this Clause 11) all
                information received or obtained by it as a result of entering into or performing this Agreement or the transactions contemplated herein which is not publicly available (or is publicly available only due to a breach of the provisions of
                this Clause 11 by one of the Parties).

            

    

     

    Subject to this Clause 11.1, each of the Parties agrees to keep the Confidential Information concerning the other Party and any of their
      Affiliates in strict confidence and that, without the prior written consent of the other Party, will not disclose or permit any other person access to the Confidential Information except as provided in this Clause 11.1.

     

    Each of the Parties and the Buyers may disclose to its permitted contractors and Affiliates any of the Confidential Information that is
      reasonably necessary for such permitted contractors to perform their duties with respect to the Rigs; provided, however, that they shall first have required their respective contractors to sign a confidentiality agreement in form and substance
      reasonably suited to implement the purpose of this Clause 11.1.

     

    Each Party shall be responsible for causing its permitted contractors and Affiliates to maintain the confidentiality of the Confidential
      Information, and each Party acknowledges and agrees that use or disclosure thereof by the receiving Party or any Affiliate, agents, representatives, servants, contractors or employees of such receiving Party, other than in accordance with the express
      terms of this Agreement or as otherwise authorised in writing by a senior officer of the disclosing party, constitutes a material breach of the Agreement or, after the Termination Date, of such disclosing Party’s continuing rights. In such event, the
      applicable receiving Party acknowledges that such disclosing Party may be immediately and irreparably harmed, that money damages may not provide full and appropriate relief, and that, notwithstanding any other provision hereof, such disclosing Party
      may therefore immediately seek to terminate this Agreement upon written notice, and to obtain an order for appropriate injunctive relief.

    
      Page 7

      
        
 

    

    
      	11.3	
              Notwithstanding the other provisions of this Clause 11, a Party and a Buyer may disclose Confidential information:

            

    

     

    
      	

            	(a)	
              if and to the extent required by applicable law, any securities exchange or governmental authority of competent jurisdiction, whether or not the requirement for information has the force of law, subject to the
                other Party agreeing to the terms of any such disclosure (to the extent that such agreement is permitted under the terms of such body), such agreement not to be unreasonably withheld or delayed;

            

    

     

    
      	

            	(b)	
              to its employees, professional advisers, auditors and banks who have been informed of the confidentiality of the information prior to disclosure, have a legitimate need to know such information and who will
                themselves be subject to a duty of confidentiality of similar nature and scope to that contained in this Clause 10;

            

    

     

    
      	

            	(c)	
              if and to the extent the information has come into the public domain through no fault of a Party or any person for whose conduct it is responsible or was lawfully in the possession of a Party prior to disclosure
                to it;

            

    

     

    
      	

            	(d)	
              which was received by from a third party without obligation of confidentiality (such Party having acted in good faith and having no reasonable ground to believe that the disclosure is in breach of any duty of
                confidentiality);

            

    

     

    
      	

            	(e)	
              if and to the extent the other Party has given prior written consent to the disclosure provided that such consent shall not be withheld or delayed in respect of any disclosure to any person who has entered into a
                confidentiality undertaking or agreement of similar nature and scope to that contained in this Clause 11,

            

    

     

    provided that in respect of (b) and (e) only, the Party who makes such disclosure shall remain liable to the other Party for the
      compliance of such person with the terms of this Clause 11.

     

    
      	11.4	
              The restrictions contained in this Clause shall continue to apply after the termination of this Agreement without limit in time.

            

    

     

    
      	12.	
              RIGHTS OF THIRD PARTIES

            

    

     

    Subject to the Buyers being able to enforce their rights as contained herein, no term of this Agreement shall be enforceable, by virtue of the Contracts
      (Rights of Third Parties) Act 1999 or otherwise, by any Person who is not a Party to this agreement. The consent of any Buyer shall not be required for the variation or termination of this Agreement, even if that variation or termination affects the
      benefit conferred on such Buyer.

     

    
      	13.	
              SURVIVAL

            

    

     

    Termination or expiry of this Agreement shall be without prejudice to any provision of this Agreement which (either expressly or impliedly) is intended
      to survive such termination or expiry (as the case may be), including without limitation Clauses 9-15 (inclusive).

    
      Page 8

      
        
 

    

    
      	14.	
              COUNTERPARTS

            

    

     

    
      	14.1	
              This Agreement may be executed in any number of counterparts but shall not be effective until each of the Parties has executed at least one counterpart.

            

    

     

    
      	14.2	
              Each counterpart shall constitute an original of this Agreement, but all the counterparts together constitute one and the same instrument.

            

    

     

    
      	15.	
              GOVERNING LAW AND DISPUTES

            

    

     

    
      	15.1	
              This Agreement and the rights of the Parties shall be governed by and construed in accordance with English law.

            

    

     

    
      	15.2	
              If any dispute between Buyer Parent and Seller arises as to any matter arising under or out of or in connection with this Agreement, the Parties shall in the first instance attempt to settle the dispute amicably
                by reference of the dispute to the senior management of the Parties for negotiation and resolution.

            

    

     

    
      	15.3	
              If the dispute remains unresolved within a fourteen (14) days period from the commencement of such negotiation, the Parties shall attempt to settle such dispute by mediation in accordance with the Mediation
                Procedure of the Singapore Mediation Centre. Neither Party may terminate the mediation until each Party has made its opening presentation and the mediator has met each Party separately. The mediation shall take place in Singapore and the
                language of the mediation shall be English. If the dispute remains unresolved within a fourteen (14) days period from the commencement of such negotiation, it shall be referred to arbitration in London in accordance with the Arbitration Act
                1996 or any statutory modification or re-enactment thereof save to the extent necessary to give effect to the provisions of this Clause.

            

    

     

    
      	15.4	
              The arbitration shall be conducted in accordance with the London Maritime Arbitrators Association (LMAA) Terms current at the time when the arbitration proceedings are commenced.

            

    

     

    
      	15.5	
              The reference shall be to three arbitrators. A Party wishing to refer a dispute to arbitration shall appoint its arbitrator and send notice of such appointment in writing to the other Party requiring the other
                Party to appoint its own arbitrator within fourteen (14) calendar days of that notice and stating that it will appoint its arbitrator as sole arbitrator unless the other Party appoints its own and gives notice that it has done so within the
                fourteen (14) days specified. If the other Party does not appoint its own arbitrator and give notice that it has done so within the fourteen (14) days specified, the Party referring a dispute to arbitration may, without the requirement of
                any further prior notice to the other Party, appoint its arbitrator as sole arbitrator and shall advise the other Party accordingly. The award of a sole arbitrator shall be binding on both Parties as if the sole arbitrator had been
                appointed by agreement,

            

    

     

    
      	15.6	
              In cases where neither the claim nor any counterclaim exceeds the sum of United States Dollars One Hundred Thousand (US$100,000) the arbitration shall be conducted in accordance with the LMAA Small Claims
                Procedure current at the time when the arbitration proceedings are commenced.

            

    

     

    
      	15.7	
              Notwithstanding the above, the Parties may agree at any time to refer to mediation any difference and/or dispute arising out of or in connection with this Agreement.

            

    

    
      Page 9

      
        
 

    

    
      	15.8	
              The Buyer Parent, the Buyer and the Seller agree they shall each appoint agent in London for the purpose of accepting service of process in any action, arbitration or proceedings brought against it in England and
                Wales with respect to this Agreement and that any service on such process agent shall be valid service for such purposes. In this regard, each of the Parties shall deliver to the other Party an appointment of process agent duly issued by it
                in favour of such process agent together with the acknowledgement issued by such process agent addressed to the other Party within fourteen (14) days of the date of this Agreement. Each of the Parties undertakes not to revoke the authority
                of such agent and if, for any reason, any agent can no longer serve as its agent to receive service of process, another agent will be immediately appointed and the other Party advised accordingly.

            

    

     

    IN WITNESS WHEREOF, the Parties to this Agreement have caused this Agreement to be duly executed on the date first above written.

     

    Signed by [***]

      for and on behalf of

     

    PPL Shipyard Pte Ltd

     
      	
               

            	
               Signature

            

    

     

    Signed by [***]

      for and on behalf of

     

    Borr Drilling Limited

     
      
        	
                 

              	
                 Signature

              

      

      
        Page 10

        
          
 

      

    

    SCHEDULE 1

      

      The Rigs

     

    Purchase Price / First Instalment / Seller’s Credit for each Rig

     

    The purchase price for each Rig shall be United States Dollars One Hundred and Thirty-Nine Million Five Hundred Thousand (US$139,500,000).

     

    
      	(i)	
              the sum of United States Dollars Fifty-Five Million and Eight Hundred Thousand (US$55,800,000) as the First Payment; and

            

    

     

    
      	(ii)	
              the balance of the purchase price amounting to United States Dollars Eighty-Three Million and Seven Hundred Thousand (US$83,700,000) as the Seller’s Credit.

            

    

     

    Interest / Admin Fee / Back-End Fee

     

    
      	(1)	
              interest on Seller’s Credit payable by Buyer quarterly as described in Clause 3(b)(i) to (iii) SPA and Clause 3.2(b)(i) to (iii) Construction Contract.

            

    

     

    
      	(2)	
              Admin Fee - as described in Clause 4.5 herein and in Clause 3(d) SPA and Clause 3.6 Construction Contract.

            

    

     

    
      	(3)	
              Back-End Fee - consisting of definite payment and uplift between valuation and Purchase Price for each Rig as described in Clause 3(c) SPA and Clause 3.5 Construction Contract.

            

    

    
      Page 11

      
        
 

    

    Delivery Date for the Rigs

     

    The estimated delivery dates for the Rigs are as follows (Rigs 1-6 being completed Rigs to be sold under SPAs and Rigs 7-9 being Rigs under construction to be sold under
      Construction Contracts):

     

    	
            Rig

          	
            Hull No.

          	
            Delivery Date

          
	
            1

          	
            P2041

          	
            15 November 2017

          
	
            2

          	
            P24,3

          	
            04 January 2018

          
	
            3

          	
            P2045

          	
            23 February 2018

          
	
            4

          	
            P2046

          	
            13 April 2018

          
	
            5

          	
            P2053

          	
            1 June 2018

          
	
            6

          	
            P2049

          	
            23 July 2018

          

    	
            7

          	
            P2047

          	
            11 September 2018

          
	
            8

          	
            P2048

          	
            31 October 2018

          
	
            9

          	
            P2052

          	
            30 January 2019

          

    
      Page 12

      
        
 

    

    FORM OF SPA

    
      Page 13

      
        
 

    

    
    SUBJECT TO CONTRACT

     

    AGREED FORM

     

    AGREEMENT FOR SALE AND PURCHASE OF

      PACIFIC CLASS 400 JACK-UP DRILLING RIG BEARING HULL NO. P[2053]

     

    This Sale and Purchase Agreement (this “Agreement”) is entered into on [●] October
      2017 Between

     

    PPL Shipyard Pte Ltd, a company incorporated under the laws of Singapore and having its registered office at 21, Pandan Road,
      Singapore 604273 (hereinafter called “Seller”),

     

    And

     

    Borr Jack-Up [●] Inc., a company incorporated under the laws of the Marshall Islands and having its registered office at Trust Company Complex, Ajeltake Road, Ajeltake Island, Majuro, Marshall Islands and an office at Thistle
        House, 4 Burnaby Street, Hamilton HM 11, Bermuda (hereinafter called “Buyer”).

     

    Seller and Buyer shall each be known as “Party” or collectively be known as “Parties”.

     

    The Parties agree that this Agreement is entered into pursuant to the Master Agreement (as defined below) and its effectiveness is subject to the
      conditions set out in Clause 2 of the Master Agreement, and will become effective, in accordance with the Master Agreement, from the Effective Date. Alternatively, this Agreement will be automatically null and void on the Termination Date (as defined
      in Clause 2.2 of the Master Agreement).

     

    Seller has agreed to sell and Buyer has agreed to buy one unit of Pacific Class 400 jack up drilling rig bearing Hull No. [P2053] at
        Seller’s shipyard in Singapore (“the Rig”) on the following terms and conditions:

     

    
      	
              1.

            	
              Definitions

            

    

     

    “Average LIBOR”, for any quarter after the Delivery Date, shall mean the average of the Monthly LIBOR for the three (3) months of that quarter or in the event of early
      repayment of the balance of the purchase price of the Rig as stated in Clause 3 by the Buyer, such average, as appropriately adjusted by the Seller.

     

    “Back End Fee” shall mean the sum payable by Buyer to Seller as stated in Clause 3(c).

    

    

    Sale and Purchase Agreement – Hull Number P[2053]

    
      1

      
        
 

    

    “Banking Days” are days on which banks are open in London, Oslo, Singapore and in New York City and excluding days which are Saturday, Sunday or public holidays in any of
      the places listed above.

     

    “Buyer’s Parent Company” means Borr Drilling Limited, a company incorporated in Bermuda, who is the parent company of the Buyer.

     

    “Classification Society” or “Class” means the American Bureau of Shipping (ABS).

     

    “Delivery Date” means [insert date set out in Schedule 1 to the Master Agreement], subject to terms of Clause 14.1.

     

    “Effective Date” has the meaning set out in the Master Agreement.

     

    “In writing” or “written” means a letter handed over from Seller to Buyer or vice versa, a registered letter, telex, telefax, email or other modern form of written
      communication.

     

    “Master Agreement” means the master agreement dated [●]
        October 2017 between the Seller and the Buyer, a copy of which is attached hereto as Exhibit 1.

     

    “Monthly LIBOR” means the 3-month USD LIBOR as quoted in Bloomberg on the first New York banking day in a calendar month (or in the event the quotation from
      Bloomberg is not available, then the quotation from any other financial reporting service as the Seller shall determine), with the first Monthly LIBOR being determined as at the first New York banking day of the calendar month when delivery of the
      Rig takes place. If LIBOR should cease to be available, it shall be replaced by the reference rate which replaces LIBOR in the London interbank market, or such other rate as the Seller and the Buyer shall agree.

     

    “Buyer’s Parent Company Guarantee” means the parent company guarantee to be provided by the Buyer’s Parent Company substantially in the form attached as
      Schedule 4 hereto.

     

    “Seller’s Parent Company Guarantee” means the parent company guarantee for payment of the First Payment as described in Clause 3 (f) to be issued by the
      Seller’s Guarantor substantially in the form attached as Schedule 5 hereto.

     

    “Seller’s Guarantor” means Sembcorp Marine Ltd., a company incorporated in Singapore, who is the parent company of the Seller issuing the Seller’s Parent
      Company Guarantee.

     

    
      	
              2.

            	
              Purchase Price

            

    

     

    The purchase price for the Rig shall be United States Dollars One hundred and thirty nine million five hundred thousand (US$139,500,000) (the “Purchase Price”).

    

    

    Sale and Purchase Agreement – Hull Number P[2053]

    
      2

      
        
 

    

    
      	
              3.

            	
              Payment

            

    

     

    
      	(a)	
              The said Purchase Price shall be paid in full, free of bank charges, to Seller as follows:

            

    

     

    
      	

            	(i)	
              the sum of United States Dollars Fifty Five Million Eight Hundred Thousand (US$55,800,000) (“the First Payment”)
                  not later than fifteen (15) Banking Days from the Effective Date, provided that the Seller’s Parent Company Guarantee has been issued in favour of Buyer; and

            

    

     

    
      	

            	(ii)	
              the balance of the Purchase Price amounting to United States Dollars Eighty three Million Seven Hundred Thousand (US$83,700,000) (“the Balance Payment”) shall be made
                available as a seller’s credit, payable [***] the date falling sixty (60) months from the actual delivery date of the Rig. No Balance Payment is due if the Rig is not delivered under this Agreement.

            

    

     

    
      	(b)	
              If the Rig is delivered under this Agreement, Buyer shall pay interest on the Balance Payment to Seller, quarterly, as follows:

            

    

     

    
      	

            	(i)	
              during the period of 36 months after the Delivery Date, at the rate of [***]% above the Average LIBOR up to the day the balance of the Purchase Price is paid to the Seller;

            

    

     

    
      	

            	(ii)	
              during the period of 12 months thereafter, at the rate of [***]% above the Average LIBOR up to the day the balance of the Purchase Price is paid to the Seller; and

            

    

     

    
      	

            	(iii)	
              during the period of 12 months thereafter, at the rate of [***]% above the Average LIBOR up to the day the balance of the Purchase Price is paid to the Seller.

            

    

     

    Seller shall invoice the Buyer in writing, for each quarter in respect of the interest payable for that quarter which interest shall be due and payable on
      the last Banking Day of that quarter. Seller’s invoices in this regard shall be conclusive evidence of such amount of interest to be payable by Buyer, save for manifest error.

     

    For the purpose of clarification and avoidance of doubt, the accrual of the interest on the Balance Payment as provided above shall commence on the actual
      delivery date of the Rig. In the event Buyer takes delivery of the Rig later than the Delivery Date, and such delay in taking delivery is not due to any delay on the part of Seller, the accrual of the interest on the Balance Payment as provided in
      this Clause 3(b) shall commence on the Delivery Date. In the event that the Buyer takes delivery earlier than the Delivery Date, interest starts to accrue on the Balance Payment from the actual delivery date.

     

    
      	(c)	
              Buyer shall pay to Seller an amount to reflect the uplift in value of the Rig at the time when Buyer pays to Seller the Balance Payment, to be defined and calculated as
                  follows:

            

    

     

    (A) A definite fixed sum of USD[***]

     

    plus

    

    

    Sale and Purchase Agreement – Hull Number P[2053]

    
      3

      
        
 

    

    (B) 25% of the increase in value of the Rig obtained from the difference between:

     

    
      	

            	(1)	
              the average of 3 independent broker quotes for the value of the Rig at the time of Buyer’s payment of the Balance Payment, and

            

    

    
      	

            	(2)	
              the Purchase Price.

            

    

     

    Less

     

    
      	

            	(a)	
              [***]% per annum of the First Payment, calculated from the date of delivery of the Rig by the Seller to the Buyer until the date the Buyer pays the Seller the Balance Payment; and

            

    

    
      	

            	(b)	
              an amount equal to the interest accrued and/or paid by Buyer to Seller in respect of the Balance Payment.

            

    

     

    In the event that the average of the 3 independent broker quotes is lower than the Purchase Price, or if the amount to reflect the uplift
      in value of the Rig as calculated above results in a negative figure, then no amount in this sub-clause (B) will be payable by the Buyer, and the Seller has no obligation to reimburse the Buyer for the shortfall.

     

    
      	(d)	
              The Buyer shall during the period from the Effective Date up to 30 January 2019 (or such other date on which the last rig is delivered under the Master Agreement) place orders worth not less than US$[***] for
                equipment and spares for the Rig by executing and issuing purchase order forms to the Seller. The Buyer shall be liable to make an additional payment of [***]% on the value of such purchase orders as administrative charges. If the total
                value of Buyer’s orders by 30 January 2019 (or such other date on which the last rig is delivered under the Master Agreement) is less than US$[***], Buyer shall pay to Seller [***]% of the shortfall. Buyer shall make payment on its orders
                within 30 days from the date of Seller’s invoice.

            

    

     

    
      	(e)	
              All payments to be effected by Buyer to Seller pursuant to this Agreement shall be remitted to the following bank account of Seller, free and clear of bank charges;

            

    

     

    [***]

      Swift Address: [***]

      FED ABA: [***]

      For A/C: UOB Singapore

      Swift Code: [***]

      For Credit of PPL Shipyard Pte Ltd

      US$ current A/C No: [***]

     

    or to such other bank account as Seller shall notify Buyer in writing from time to time.

     

    
      	(f)	
              Payment by Buyer of the First Payment in accordance with Clause 3(a) (i) is conditional upon Seller providing Buyer with the Seller’s Parent Company Guarantee.

            

    

     

    
      	(g)	
              Buyer’s obligation to pay the Balance Payment (and any interest thereon as provided in Clause 3(b) herein) and Buyer’s obligation to pay the Back End Fee shall be secured by the Buyer’s Parent Company Guarantee
                from Borr Drilling Limited.

            

    

     

    Sale and Purchase Agreement – Hull Number P[2053]

    
      4

      
        
 

    

    
      	(h)	
              Buyer’s obligation to pay the Balance Payment (and any interest thereon as provided in Clause 3(b) herein) and Buyer’s obligation to pay the Back End Fee shall be secured by a first priority mortgage over the Rig
                and a first party assignment of the insurances and requisition compensation of the Rig.

            

    

     

    
      	(i)	
              Seller shall have the right to assign its rights to receive payment of the Balance Payment (and interest thereon) from the Buyer and its rights to receive payment of the Back End Fee from the Buyer and, in
                connection therewith, its rights to, and interests in the security documents as hereinafter defined at Clause 11.1 and the Buyer’s Parent Company Guarantee to any third party including any financial institution with prior written consent of
                the Buyer Parent (such consent not to be unreasonably withheld).

            

    

     

    
      	(j)	
              Buyer shall at its own cost on execution of this Agreement provide Seller with a corporate guarantee (the “Parent Company Guarantee”) from Borr Drilling Limited in respect of the performance of Buyer’s obligations
                under this Agreement. The Parent Company Guarantee shall be in the form set out in Schedule 4 of this Agreement.

            

    

     

    
      	
              4.

            	
              Time and Place of Delivery

            

    

     

    
      	4.1	
              Time and place for delivery: The Rig shall be delivered and taken over by Buyer at a safe and accessible berth alongside Seller’s shipyard in Singapore on the Delivery Date.

            

    

     

    
      	4.2	
              [For 5 completed Rigs] Seller has obtained ABS Class Certificate and these Rigs are presently laid up at Seller’s yard. Buyer accepts the Rig complete with its present documentation and drawings as per the
                inspection at the signing of this Agreement. Buyer shall bear the cost and time impact of any changes required by Buyer. The Rig will be delivered and taken over in substantially the same condition as at the time of inspection at the
                signing of this Agreement, fair wear and tear excepted.

            

    

     

    [For P2053] The Rig is substantially completed and is presently laid up at Seller’s yard. Most of the remaining minor scope of work
      requires the Buyer’s information. Buyer shall provide the requisite information as set out in Schedule 2 within 14 days from the date of this Agreement. Buyer accepts the Rig complete with its present documentation and drawings as per the inspection
      at the signing of this Agreement except for the remaining minor scope of work which Seller will complete upon receiving Buyer’s requisite information. Buyer shall bear the cost and time impact of any changes required by Buyer. The Rig will be
      delivered and taken over in substantially the same condition as at the time of inspection at the signing of this Agreement, fair wear and tear excepted.

     

    In the period between the date of signing this Agreement and the Delivery Date, the Rig will be maintained by the Seller in accordance
      with the Seller’s preservation regime at the time of inspection.

    

    

    Sale and Purchase Agreement – Hull Number P[2053]

    
      5

      
        
 

    

    
      	4.3	
              In the event Buyer takes delivery of the Rig later than the Delivery Date, and such delay in taking delivery is not due to any delay on the part of Seller, Buyer shall compensate Seller for the additional costs to
                keep the Rig at Seller’s yard, including but not limited to the costs of preservation, maintenance, storage and insurance for the Rig.

            

    

     

    
      	4.4	
              Should the Rig become an actual, constructive or compromised total loss before delivery, the First Payment shall be refunded by Seller, together with interest thereon at the same rate stated in Clause 3(b)(i)
                (i.e. US$ LIBOR plus [***]% p.a.) to Buyer and this Agreement shall be terminated and neither Party hereto shall have any claims against the other Party pursuant to, or in connection with, this Agreement other than the Seller’s obligation
                to refund the First Payment.

            

    

     

    
      	
              5.

            	
              Equipment/Spares/Bunkers and other items

            

    

     

    
      	5.1	
              Seller shall deliver the Rig to Buyer with the equipment as specified in the specifications for the Rig. Spares are not included in this sale. Items on board which are on hire or owned by third parties (if any)
                are also excluded from the sale.

            

    

     

    
      	5.2	
              An inventory of unused lubricating oil, grease, fuel oil or other liquids, supplied by Seller and left on board at delivery of the Rig shall be purchased and paid for by Buyer. Buyer will take over the remaining
                bunkers and unused lubricating oils in storage tanks and unbroached drums and pay the current market price for the quantities taken over. Payment under this Clause 5 shall be made by Buyer to Seller at the time of delivery of the Rig in the
                same currency as the Purchase Price.

            

    

     

    
      	
              6.

            	
              Warranty

            

    

     

    
      	6.1	
              Seller does not provide warranty for the Rig but the Buyer shall be assigned the benefit of warranties from suppliers [of equipment purchased pursuant to Clause 3(d) and all other supplier warranties] which have
                not expired on delivery of the Rig and Buyer shall seek its remedies or enforce its rights against the suppliers in the event of a warranty claim in respect of such warranties which have been assigned to it at its sole cost and expense.

            

    

     

    
      	
              7.

            	
              Closing/Delivery

            

    

     

    
      	7.1	
              The place for dosing of delivery for the Rig shall be at Seller’s office in Singapore.

            

    

     

    
      	7.2	
              Buyer shall take delivery of the Rig on the Delivery Date unless this Agreement is terminated by Buyer due to an Event of Default by Seller under Clause 14.

            

    

     

    
      	7.3	
              Buyer shall be responsible for registration and documentation of the Rig in the name of Buyer in the Panama Register of Shipping and all expenses incurred with respect thereto shall be paid and be solely for the
                account of Buyer. In this regard, as soon as practicable after receipt of the First Payment, Seller shall forward, by email or fax, copies of the Builder’s Certificate of the Rig duly notarised, the Class Attestation or Classification
                Certificate of the Rig and the Tonnage Attestation or Tonnage Certificate of the Rig (collectively “the Provisional Registration Documents”) to enable Buyer to provisionally register the Rig in their name in the Panama Register of Shipping.
                Buyer shall forward a copy of the provisional certificate of Panamanian Registry of the Rig issued in their name to Seller not later than seven (7) days from the date of receipt by Buyer of the Provisional Registration Documents from
                Seller.

            

    

     

    Sale and Purchase Agreement – Hull Number P[2053]

    
      6

      
        
 

    

    
      	7.4	
              At the time of delivery, Buyer and Seller shall sign and deliver to each other a Protocol of Delivery confirming the date and time of delivery of the Rig from Seller to Buyer.

            

    

     

    
      	7.5	
              The Rig is presently built to the requirements of the [Panama / Port Klang Malaysia /Singapore] flag registry. Seller will inform Class of Buyer’s intent to register the Rig under the Panamanian ship registry if
                it decides to change the flag of the Rig [Port Kiang Malaysia or Singapore only]. In the event that there is any work required to be carried out on the Rig to comply with the requirements of the Panamanian ship registry, such work shall be
                treated as variation order, and any cost and time impact on Delivery Date shall be borne by Buyer.

            

    

     

    
      	
              8.

            	
              Documentation

            

    

     

    
      	8.1	
              Seller shall deliver the following documents to Buyer at closing on the Delivery Date, to the extent not already delivered pursuant to Clause 7.3:

            

    

     

    
      	

            	(a)	
              executed and notarized Bill of Sale for the Rig recordable in Panama and stating that the Rig is free and clear of all liens, security, interests, claims and encumbrances, duly notarised.

            

    

     

    
      	

            	(b)	
              executed and notarized Builder’s Certificate, duly notarised.

            

    

     

    
      	

            	(c)	
              the classification certificate and the tonnage certificate of the Rig.

            

    

     

    
      	

            	(d)	
              Declaration of Warranty of Seller that the Rig and any equipment forming part of the Rig is delivered to Buyer free and clear of all Liens, claims, retention of title arrangements or other encumbrances, and in particular that the Rig is
                absolutely free of all burdens in the nature of imposts, taxes or charges imposed by local Singapore authorities, as well as, of all liabilities of Seller to its subcontractors, employees, crew and others and of all liabilities arising from
                the operation of the Rig during trial tests and commission or otherwise prior to Closing.

            

    

     

    
      
        	
                

                

              	
                (e)

              	
                a commercial invoice for the Balance Payment signed by a director, officer or other person authorised to represent Seller.

              

      

      

      

      Sale and Purchase Agreement – Hull Number P[2053]

      
        7

        
          
 

      

    

    
      	
              

              

            	(f)	
              a commercial invoice for the First Payment marked “Paid” signed by a director, officer or other person authorised to represent Seller.

            

    

     

    
      	

            	(g)	
              extract of resolutions of the board of directors of Seller, certified as a true copy by the Company Secretary or a Director of Seller, approving and ratifying the entry into this Agreement and the transactions contemplated hereby and
                appointing a designated person under the said resolutions to sign the Bill of Sale, Protocol of Delivery and Acceptance and the other Seller’s delivery documents (as defined in Clause 11) and to deliver the Rig from Seller, such copy
                bearing a certificate signed by a director or officer of Seller as to the completeness and validity of the resolution(s).

            

    

     

    
      	

            	(h)	
              Drawings, plans and manuals pertaining to the Rig as stipulated in the specifications for the Rig.

            

    

     

    
      	

            	(i)	
              Protocol of Trials of the Rig made pursuant to the specifications for the Rig, if applicable.

            

    

     

    
      	

            	(j)	
              Protocol of Inventory and Equipment of the Rig, as detailed in the specifications for the Rig.

            

    

     

    
      	

            	(k)	
              Protocol of Stores of Consumable Nature, such as fuel oil, lubricating oil and greases, fresh water etc. which are on board and payable by Buyer to Seller.

            

    

     

    
      	

            	(l)	
              all certificates, including but not limited to classification certificates, and other documents required to be furnished on delivery pursuant to this Agreement.

                

                In the event that any required certificates are not available at the time of delivery, Buyer shall accept interim certificates provided that Seller, at its cost and expense, provides Buyer with final certificates as promptly as possible.

            

    

     

    
      	

            	(m)	
              Certificate of Non-Registration issued by Seller confirming that the Rig is not, on the Delivery Date, registered in any registry or other record Delivery Date.

            

    

     

    
      	

            	(n)	
              any other documents reasonably required by Buyer for the purpose of registering the Vessel in Panama, but only to the extent that such document(s) is/are within Seller’s power and control to provide.

            

    

     

    
      	8.2	
              Buyer shall deliver the following documents to Seller at closing or the Delivery Date.

            

    

     

    
      	

            	(a)	
              A Certificate of Incumbency for Buyer listing the current directors and officers of Buyer signed by a director or other person authorised to represent Buyer under power of attorney.

            

    

     

    
      	

            	(b)	
              A certified copy of a resolution of all the members of the board of directors of Buyer, approving the terms of this Agreement and the transactions contemplated herein and appointing a designated person under power of attorney to sign the
                Protocol of Delivery and Acceptance, the other Buyer’s delivery documents and the Security Documents (as hereinafter defined) and to accept delivery of the Rig from Seller, such copy bearing a certificate signed by a director or officer of
                Buyer as to the completeness and validity of the resolution(s).

            

    

     

    Sale and Purchase Agreement – Hull Number P[2053] 

    
      8

      
        
 

    

    
      	

            	(c)	
              an original Power of Attorney of Buyer authorising Buyer’s appointed representative(s) to execute all necessary documents and take all necessary action in order to purchase and complete the purchase and take delivery of the Rig and
                execute the Security Documents (as hereinafter defined), duly notarised.

            

    

     

    
      	

            	(d)	
              the Acceptance of Sale of the Rig, in the requisite Panamanian format, duly notarised.

            

    

     

    [For Malaysian and Singapore flag rig: Borr has the option to retain Malaysian and/or Singapore flag and all references to Panama will be construed
      accordingly]

     

    
      	8.3	
              The Parties will deliver each to the other draft copies of their delivery documentation not later than twenty-one (21) days prior to the anticipated date of delivery for each Party to review the other Party’s
                documents.

            

    

     

    
      	
              9.

            	
              Encumbrances

            

    

     

    
      	9.1	
              Seller warrants that the Rig, at the time of delivery, is free and clear of all liens, security, interests, claims and encumbrances.

            

    

     

    
      	9.2	
              Seller hereby undertakes to indemnify Buyer against any claim made against the Rig which have been incurred prior to the time of delivery.

            

    

     

    
      	
              10.

            	
              Taxes, Fees and Expenses

            

    

     

    
      	10.1	
              Any taxes, fees and expenses imposed on Buyer in connection with the purchase and registration of the Rig in Buyer’s nominated flag state shall be for Buyer’s account.

            

    

     

    
      	10.2	
              Any taxes, fees and expenses imposed on Seller in connection with this Agreement in relation to the construction and the sale of the Rig prior to Delivery, including tax on wages and salaries and corporate tax,
                shall be for Seller’s account.

            

    

     

    
      
        	
                10.3

              	
                The Seller confirms that there is no GST or similar sales tax or duty payable on the Purchase Price or otherwise in connection with the sale of the Rig.

              

      

      
        

        

        Sale and Purchase Agreement – Hull Number P[2053]

        

      

      
        9

        
          
 

      

    

    
      	
              11.

            	
              Title and Risk/Security

            

    

     

    
      	11.1	
              The title to the Rig will be transferred by Seller to Buyer as at the date and time of delivery of the Rig stated in the Protocol of Delivery mentioned in Clause 7.4.

            

    

     

    As security for the due fulfilment of their obligations to the Seller pursuant to this Agreement, Buyer shall, forthwith upon delivery of the Rig to it
      pursuant to this Agreement, execute a first preferred Panamanian naval mortgage of the Rig (in such number of sets as required by the Seller) (the “Mortgage”) together with any accompanying registration form,
      as required by the Panama Register of Shipping, and a deed of assignment of the insurances and requisition compensation of the Rig in favour of Seller (collectively “the Security Documents”). Seller shall, at
      Buyer’s cost, cause the title to the Rig and the Mortgage (together with any accompanying registration form as required by the Panama Register of Shipping) to be registered with the Panama Register of Shipping.

     

    Concurrently with the execution of the Security Documents, Buyer shall deliver to Seller the original hull and machinery, increased value and excess
      disbursements (if any) and war risks (if any) insurance policies of the Rig, together with a copy of the P&I Certificate of Insurance or Certificate of Entry of the Rig and such other documents as Seller shall reasonably require. Buyer shall also
      notify Seller of the name and contact details of the Rig’s insurance brokers forthwith upon Seller’s request.

     

    
      	11.2	
              Risk for loss and damage in the Rig shall vest with Seller until delivery and shall pass to Buyer on delivery.

            

    

     

    
      	11.3	
              Seller shall be entitled to exercise a lien on the Rig until the Mortgage in favour of Seller on the Rig has been registered with the Panama Register of Shipping.

            

    

     

    
      	
              12.

            	
              Buyer’s Representative

            

    

     

    There will be no Buyer’s representative permanently placed on board the Rig in the period between the Effective Date and the Delivery Date, provided
      however that in the event that at any time after the Effective Date and prior to the Delivery Date, Buyer and its clients need to board the Rig for its clients’ visit, Buyer shall obtain Seller’s written consent, and such consent shall not be
      unreasonably withheld, and Seller shall accompany Buyer for the visit on the Rig.

     

    
      	
              13.

            	
              Buyer’s Default and Termination

            

    

     

    
      	13.1	
              The following shall constitute events of default of Buyer under this Agreement:

            

    

     

    
      	

            	(a)	
              Should the First Payment not be paid in accordance with Clause 3(a)(i), Seller shall have the right to cancel this Agreement in its sole discretion on notice to Buyer, such cancellation notice having immediate effectiveness, and neither
                Party shall have any further obligation to the other Party except for obligations under this Agreement that survive termination.

            

    

     

    Sale and Purchase Agreement – Hull Number P[2053] 

    
      10

      
        
 

    

    
      	

            	(b)	
              If, after the Delivery Date, Buyer fails to pay the Balance Payment as stated in Clause 3(a)(ii), or fails to pay the quarterly interest on the Balance Payment as stated in Clause 3(b), or fails to pay the Back End Fee as stated in
                Clause 3(c), or if after the Delivery Date, Buyer or Buyer Parent is voluntarily or involuntarily made a part of any receivership, liquidation or bankruptcy proceedings or Buyer or Buyer Parent becomes insolvent or otherwise unable to meet
                all or part of its financial or other obligations under this Agreement, or if an event of default occurs under the terms of any of the Security Documents; or

            

    

     

    
      	

            	(c)	
              If, in the reasonable opinion of the Seller, any of the securities granted to the Seller under the terms of the Security Documents are in jeopardy and notice thereof has been given to the Buyer, or

            

    

     

    
      	

            	(d)	
              If, after the Delivery Date, anything is done or omitted to be done by the Buyer’s Parent Company which in the reasonable opinion of the Seller, materially impairs or renders insufficient or inadequate the Buyer’s Parent Company
                Guarantee; or

            

    

     

    
      	

            	(e)	
              If, after the Delivery Date, there should occur any event or change or series of events which in the reasonable opinion of Seller, would have a material or adverse effect on the business or financial condition of the Buyer or the Buyer’s
                Parent Company or a material or adverse effect on the ability of the Buyer’s Parent Company to perform its obligations under the Buyer’s Parent Company Guarantee.

            

    

     

    
      	

            	(f)	
              If, after the Delivery Date, any indebtedness of an amount more than [***]% of the Buyer’s Parent Company’s tangible net worth, is not paid when due, or is or is declared to be or is capable of being declared due and payable before its
                normal maturity,

            

    

     

    Seller shall have the remedies as specified in the Security Documents. In this regard, in the event there is a shortfall in the proceeds of any judicial
      or mortgagee’s sale of the Rig, Seller shall have the right to claim the balance of the indebtedness due to them pursuant to this Agreement from Buyer. In the event Seller realises a surplus from any mortgagee’s sale of the Rig, Seller shall be
      entitled to retain such surplus. For the purpose of clarification and avoidance of doubt, in such an event, Seller shall also have the right to appropriate and forfeit the First Payment and any interest already paid by Buyer pursuant to Clause 3(b)
      (i)-(iii), and the Parties acknowledge that the appropriation and forfeiture of the First Payment and any interest already paid by Buyer pursuant to Clause 3(b) (i)-(iii) by Seller is a reasonable and agreed pre-estimate of the Seller’s loss and not
      a penalty, and that this is a reasonable allocation of risks between the Parties and that the Purchase Price is established on these terms.

    

    

    Sale and Purchase Agreement – Hull Number P[2053] 

    
      11

      
        
 

    

    
      	

            	(g)	
              If Seller tenders the Rig for delivery in accordance with the terms of this Agreement and Buyer fails to take delivery of the Rig within twenty one (21) days of the Delivery Date; or

            

    

     

    
      	

            	(h)	
              If prior to the Delivery Date, Buyer or Buyer Parent is voluntarily or involuntarily made a part of any receivership, liquidation or bankruptcy proceedings and such proceedings are not discharged within thirty (30) days or Buyer or Buyer
                Parent becomes insolvent or otherwise unable to meet all or part of its financial or other obligations under this Agreement and such proceedings are not discharged within thirty (30) days; or

            

    

     

    
      	

            	(i)	
              In the event Buyer fails to comply with its obligations under Clause 7.3 and fails to rectify such non-compliance within fourteen (14) days of the Seller’s written notice to Buyer to do so; or

            

    

     

    [For P2053: (h) In the event Buyer fails to comply with its obligations under Clause 7.3 or Clause 4.2, and fails to rectify such non-compliance within
      fourteen (14) of the Seller’s written notice to Buyer to do so;]

     

    
      	

            	(j)	
              If, before the Delivery Date, there should occur any event or change or series of events which in the reasonable opinion of Seller, would have a material or adverse effect on the business or financial condition of the Buyer or the
                Buyer’s Parent Company or a material or adverse effect on the ability of the Buyer’s Parent Company to perform its obligations under the Buyer’s Parent Company Guarantee; or

            

    

     

    
      	

            	(k)	
              If, before the Delivery Date, any indebtedness of an amount more than [***]% of the Buyer’s Parent Company’s tangible net worth, is not paid when due, or is or is declared to be or is capable of being declared due and payable before its
                normal maturity,

            

    

     

    Seller shall have the right to terminate this Agreement and appropriate and forfeit the First Payment and retain the Rig, and the Parties acknowledge
      that the appropriation and forfeiture of the First Payment by Seller is a reasonable and agreed pre-estimate of the Seller’s loss and not a penalty, and that this is a reasonable allocation of risks between the Parties and that the Purchase Price is
      established on these terms.

     

    
      	
              14.

            	
              Seller’s Default and Termination

            

    

     

    
      	14.1	
              Should Seller fail to be ready to validly complete a legal transfer of the Rig by the Delivery Date, the Buyer shall be entitled to cancel this Agreement, save that in the event the Rig is damaged due to any
                reason whatsoever prior to the Delivery Date and written notice thereof has been given to Buyer, Buyer shall only be entitled to cancel this Agreement in the event Seller is unable to rectify the damage and deliver the Rig to Buyer in such
                conditions as required under this Agreement, within 210 days of the event causing the damage. If this 210 days rectification period extends beyond the Delivery Date, the Buyer shall not be entitled to terminate for late delivery until such
                rectification period has expired. This rectification provision does not apply in the events as described in Clause 4.4. In the event that Buyer elects to cancel this Agreement, the First Payment together with interest thereon at the same
                rate stated in Clause 3(b)(i) (i.e. US$ LIBOR plus [***]% p.a.) from the date of payment by the Buyer, shall be immediately refunded by Seller to Buyer without the need for further demand or process. When the refund with interest is paid in
                full, Seller shall have no further liability to Buyer, pursuant to, or in connection with, this Agreement.

            

    

     

    Sale and Purchase Agreement – Hull Number P[2053] 

    
      12

      
        
 

    

    
      	14.2	
              Without prejudice to the condition for payment of the First Payment as set out in Clause 3(a)(i), if Seller fails to provide the Seller’s Parent Company Guarantee within 10 days of the date of this Agreement, the
                Buyer shall have the right to cancel this Agreement in its sole discretion on notice to Seller, such cancellation notice having immediate effectiveness and neither Party shall have any further obligation to the other Party.

            

    

     

    
      	14.3	
              If, prior to the delivery of the Rig, Seller or the Seller’s Guarantor is voluntarily or involuntarily made a part of any receivership, liquidation or bankruptcy proceedings and provided such proceedings are not
                discharged within thirty (30) days or Seller or the Seller’s Guarantor becomes insolvent or otherwise unable to meet all or part of its financial or other obligations under this Agreement, Buyer shall have the right to terminate this
                Agreement and the First Payment, together with interest thereon at the rate set out in Clause 3 (b)(i) (i.e. US$ LIBOR plus [***]% p.a.) calculated from the date of payment by the Buyer shall be refunded to Buyer immediately.

            

    

     

    
      	14.4	
              The Seller irrevocably agrees that if, following a demand by the Buyer for repayment under this Clause 14, Seller or Seller’s Guarantor does not make immediate refund to Buyer, Buyer shall be entitled to serve
                notice exercising its right to pay the Balance Payment and the Back End Fee and take delivery of the Rig under this Agreement.

            

    

     

    
      	
              15.

            	
              Consequential Loss / Liability

            

    

     

    
      	15.1	
              Save for Seller’s liability under Clause 9.2 (Encumbrances) above and except for a breach of Clause 16, neither Buyer nor Seller shall be liable to the other under this Agreement (including under any indemnity save as aforesaid) for any
                of the following (whether direct, indirect or consequential): loss of use of the Rig, loss of time, loss of production, loss of business, loss of contracts, loss of charter hire, loss of opportunity, loss of goodwill or reputation, loss of
                profits or earnings or anticipated revenue, financing costs, losses or claims resulting from failure to meet any contractual commitments or deadlines and downtime of facilities or equipment or any other property, or for any financial or
                economic loss, nor shall either Buyer or Seller be liable to the other under this Agreement (including under any indemnity save as aforesaid), for any incidental, indirect, consequential, exemplary, special or punitive losses or damages of
                any kind whatsoever, howsoever the same may have been caused or arisen whether by way of indemnity or by reason of any breach of warranty, breach of contract, negligence, tort, strict liability, statutory duty or by reason of anything under
                common law, equity or otherwise, and whether or not foreseeable as at the date of this Agreement.

            

    

     

    Sale and Purchase Agreement – Hull Number P[2053] 

    
      13

      
        
 

    

    
      	15.2	
              With the exception of Seller’s liability under Clause 9.2 (Encumbrances) above, Seller’s maximum liability to Buyer arising out of or in connection with this Agreement for any loss or damage including but not
                limited to: costs, claims or expenses, howsoever they may have been caused or arisen, whether arising under common law, contract, negligence, tort, equity, strict liability, statute or otherwise shall be limited in the aggregate to [***]
                percent ([***]%) of the Purchase Price. Buyer agrees to release Seller, its officers and servants, from and against any liability in excess thereof. For pollution related issues after delivery of the Rig, Buyer shall indemnify and hold
                Seller harmless, provided however that in the event where within twelve (12) months after the delivery of the Rig, if such pollution issues are caused by Seller’s negligence in the design or construction of the Rig, Seller shall indemnify
                and hold Buyer harmless for an amount up to United States Dollars One Million (US$1,000,000) only. Seller and Buyer agree that this provision is a reasonable allocation of risks between the Parties and that the Purchase Price is established
                on these terms.

            

    

     

    
      	16.	
              Compliance with Laws

            

    

     

    
      	16.1	
              Each of Buyer and Seller warrants and undertakes to the other that:

            

    

     

    
      	

            	(a)	
              while acting in connection with this Agreement, it will not violate or assist or instigate any other individual or legal entity to violate, any applicable law, including without limitation the United Kingdom Bribery Act 2010 and the
                United States Foreign Corrupt Practices Act or any other anti-bribery, anti-corruption anti-terrorism or money laundering law or regulation to which they are subject;

            

    

     

    
      	

            	(b)	
              all of their respective officers, employees, consultants, representatives, agents, business partners, joint-ventures and affiliates who are engaged in implementing this Agreement shall:

            

    

     

    
      	

            	(i)	
              be knowledgeable regarding the purpose and provisions of all applicable anti-corruption, anti-bribery, anti-terrorism or money laundering laws;

            

    

     

    
      	

            	(ii)	
              comply with applicable anti-bribery, anti-corruption, money laundering or anti-terrorism laws; and

            

    

     
    
      	

            	(iii)	
              not take, or will refrain from taking, any action which would cause either Buyer or Seller to be in violation of the terms of applicable anti-bribery and anti-corruption laws.

            

    

     

    
      	16.2	
              Buyer warrants and undertakes to Seller that:

            

    

     

    
      	

            	(a)	
              the execution, delivery, and performance of the transaction contemplated under this Agreement shall be in compliance with all applicable laws including, without limitation, all applicable Export and Import Laws (as defined below).

            

    

    

      Sale and Purchase Agreement – Hull Number P[2053]

      
        14

        
          
 

      

    

     

    
      	

            	(b)	
              Buyer is unconditionally responsible for complying with such laws;

            

    

     

    
      	

            	(c)	
              neither Buyer nor any of its affiliates, or successor in interest, nor any client/operator or its affiliates, is or will be a person, company, or entity:

            

    

     

    
      	

            	(i)	
              with whom Seller is prohibited from dealing or otherwise engaging in any transaction by any law related to the proliferation of nuclear, missile, or chemical/biological weapons, or missiles that deliver such
                weapons;

            

    

     

    
      	

            	(ii)	
              with whom Seller is prohibited from dealing or otherwise engaging in any transaction by any law related to transactions involving countries against which any government of the United Kingdom (“UK”) or the United
                States of America (“US”), the Organisation for Economic Cooperation and Development (“OECD”), the European Union or other international organization maintains economic sanctions or embargoes under statute, executive order or regulations;

            

    

     

    
      	

            	(iii)	
              appearing on any applicable list of prohibited parties maintained by any of the governments referred to above; or

            

    

     

    
      	

            	(iv)	
              acting or purporting to act, directly or indirectly, on behalf of, or an entity owned or controlled by, any party identified in paragraph 14.2(c) above.

            

    

     

    
      	

            	(d)	
              it shall not export the Rig and/or any related equipment (including without limitation, any accompanying technology, software or other technical data) directly or indirectly without the necessary authorizations,
                licenses, permits or approvals from the UK, US or other relevant government authority as required by the relevant Export and Import Laws except that, in the case of any such applicable trade restrictions outside the UK and US laws, only to
                the extent consistent with such UK or US laws.

            

    

     

    All laws and regulations that govern the restrictions and prohibitions referenced in paragraphs 16.2(c) and (d) shall be referred to as Export and Import
      Laws.

     

    
      	16.3	
              Seller shall abide by and comply with all valid laws and regulations of Singapore. Seller will avoid or refrain from doing anything under this Agreement which may be an actual or possible breach of any sanctions,
                prohibition or requirement imposed by the laws, regulations, resolutions, or administrative orders of the United States of America, United Nations, European Union or any other jurisdiction applicable to any of Seller’s obligations under
                this Agreement. Where Seller is so prevented from performing any work or obligation under this Agreement, Seller shall have no liability to Buyer for its inability to perform this work or obligation and Seller shall be entitled to deliver
                the Rig to Buyer without the relevant work or obligation being performed, subject to an appropriate price adjustment. In the case where such prevention occurs after delivery of the Rig, Seller shall be entitled to avoid performing the
                affected post-delivery work or obligation, if any.

            

    

     

    Sale and Purchase Agreement – Hull Number P[2053] 

    
      15

      
        
 

    

    
      	16.4	
              Should any governmental law, regulation, ruling and/or policy (including but not limited to import/export restrictions, exchange controls or requirements) effectively prohibit or restrict Seller from receiving
                payment under this Agreement, then Seller shall promptly notify Buyer of any such restriction or prohibition and the Parties shall discuss to find a mutually acceptable solution.

            

    

     

    
      	16.5	
              Where Seller is prevented from performing its obligations under this Agreement by any actions or causes attributable to Buyer, and such prevention continues for more than fourteen (14) days without being resolved,
                then this Agreement may at Seller’s option be terminated. In the event of such termination, the provisions of Clause 13 shall apply.

            

    

     

    
      	
              17.

            	
              Miscellaneous

            

    

     

    
      	17.1	
              This Agreement and all information exchange between Seller and Buyer, including all prices and any information such as documents, design, drawings, specifications, instructions, manuals, computer programs relating
                to the design and construction of the Rig which are provided by Seller to Buyer or which may otherwise be acquired by Buyer, regardless of whether they are Seller’s proprietary information, shall not be disclosed to any third party (except
                as may be required by applicable law, stock exchange, or regulatory authorities) without the prior authorization of Seller. Buyer shall be responsible for keeping confidential all such information, and shall not permit any such information
                to be shown, reproduced or otherwise disclosed to any third party by itself, its subcontractors or their respective personnel.

            

    

     

    
      	17.2	
              Where a provision in this Agreement for any reason becomes unenforceable or invalid, the remainder of the Agreement shall remain in full force and effect. Where severance of a non-enforceable provision in the
                opinion of either Party materially affects the other rights or obligations under the Agreement, the Parties shall endeavour to remedy the situation to their mutual satisfaction.

            

    

     

    
      	17.3	
              The Parties have entered into this Agreement freely, willingly, and on equal commercial basis, having had the opportunity to fully consider the contents of the Agreement. It is hereby agreed that no terms or
                conditions herein shall be construed against a Party simply by reason that the Party had proffered a particular term or condition.

            

    

     

    
      	17.4	
              Save as set forth in this Agreement, a person who is not a Party to this Agreement has no right whatsoever to enforce any term of this Agreement. For the avoidance of doubt, the Parties agree that the application
                of any statutes which may confer rights on third parties is expressly excluded.

            

    

     

    
      	17.5	
              Neither Party may transfer, assign or novate any of its rights or obligations under this Agreement, except with the prior written consent of the other Party which shall not be unreasonably withheld.

            

    

     

    Sale and Purchase Agreement – Hull Number P[2053] 

    
      16

      
        
 

    

    
      	17.6	
              This Agreement maybe signed on separate counterparts, each of which, when so executed, shall be treated as an original, but both counterparts shall together constitute one and the same document. Signatures on
                scanned copy of this Agreement may be exchanged by email, with signatures on the original documents to follow. Each Party agrees to be bound by its own signature on scanned copy of this Agreement and each Party accepts the same of the other
                Party.

            

    

     

    
      	17.7	
              The Parties shall continue to be bound by the provisions of this Agreement that reasonably require some action or forbearance after termination.

            

    

     

    
      	17.8	
              This Agreement contains the entire contract and understanding between the Parties hereto and supersedes all prior negotiations, representations, understandings and agreements on any subject matter of this
                Agreement.

            

    

     

    
      	17.9	
              Any amendment or modification to the terms of this Agreement shall be of no force or effect unless the same has been reduced to writing and signed by the duly authorized signatories of the Parties. Without
                prejudice to the generality of the foregoing the Parties undertake not to rely on any such amendment or modification unless the same has been made in the manner aforesaid.

            

    

     

    
      	
              18.

            	
              Notices

            

    

     

    
      	18.1	
              All notices and communications required to be given hereunder shall be in the English language and be served by delivering the same by courier or in person to such other Party, or by email with a transmission
                report evidencing the successful transmission of the same.

            

    

     

    
      	18.2	
              Such notices and communications shall be addressed to the respective Party’s authorized representative below.

            

    

     

    
      	18.3	
              Notice so given shall be effective if and when (as the case may be) it arrives by courier at the specified address or is delivered in person at the specified address, or is successfully transmitted (as evidenced
                by a transmission report) by email regardless of the time when it is first personally received or seen by, or otherwise comes to the attention of, the relevant Party, or its authorized representatives.

            

    

    

      Sale and Purchase Agreement – Hull Number P[2053]

    
      17

      
        
 

    

    Any and all notices and communications in connection with the Agreement shall be addressed as follows:

     

    Buyer

        BORR JACK-UP [●] INC.

        c/o Quorum Services Limited, Thistle House, 4 Burnaby Street, Hamilton HM 11, Bermuda

    

      Telephone:

      Email: [***]

      Attention: [***], (Chief Operating Officer)

     

    Seller

      PPL SHIPYARD PTE LTD

      21, Pandan Road

      Singapore 609273

      Telephone No: [***]

      Telefax No:          [***]

      Email: [***]

      Attention: [***]

     

    
      	
              19.

            	
              Confidentiality

            

    

     

    
      	19.1	
              Except with the consent of both Parties, neither Party shall (whilst ensuring that its affiliates, directors, employees, agents and advisers shall not) disclose the existence of or any of the provisions of this
                Agreement and the documents attached to it to any third party and shall safeguard, hold in the strictest confidence and not disclose to any third party or use for the purposes of its own business any information, data, documents and
                materials which it acquires in connection with this Agreement and all matters related to it (“Confidential Information”) except, as may be required by law or by any relevant national or supranational regulatory authority or by the rules of
                any relevant stock exchange.

            

    

     

    
      	19.2	
              Each of the Parties shall however be entitled to disclose the Confidential Information to that Party’s professional, financial advisers, potential investors, equipment vendors and specialist consultants who are
                required to know the same to carry out their duties including raising funds for the Party in question provided that such Party shall procure that such professional and financial advisers, etc, shall enter into a confidentiality agreement in
                the same terms as this clause in favour of Seller and/or Buyer (as the case may be).

            

    

     

    
      	
              20.

            	
              Dispute Resolution

            

    

     

    
      	20.1	
              This Agreement shall be governed and construed by and in accordance with English law.

            

    

     

    
      	20.2	
              If any dispute between Buyer and Seller arises as to any matter arising under or out of or in connection with this Agreement, the Parties shall in the first instance attempt to settle the dispute amicably by
                reference of the dispute to the senior management of the Parties for negotiation and resolution.

            

    

     

    
      	20.3	
              If the dispute remains unresolved within a fourteen (14) days period from the commencement of such negotiation, it shall be referred to arbitration in London in accordance with the Arbitration Act 1996 or any
                statutory modification or re-enactment thereof save to the extent necessary to give effect to the provisions of this Clause.

            

    

     

    Sale and Purchase Agreement – Hull Number P[2053] 

    
      18

      
        
 

    

    
      	20.4	
              The arbitration shall be conducted in accordance with the London Maritime Arbitrators Association (LMAA) Terms current at the time when the arbitration proceedings are commenced.

            

    

     

    
      	20.5	
              The reference shall be to three arbitrators. A Party wishing to refer a dispute to arbitration shall appoint its arbitrator and send notice of such appointment in writing to the other Party requiring the other
                Party to appoint its own arbitrator within fourteen (14) calendar days of that notice and stating that it will appoint its arbitrator as sole arbitrator unless the other Party appoints its own and gives notice that it has done so within the
                fourteen (14) days specified. If the other Party does not appoint its own arbitrator and give notice that it has done so within the fourteen (14) days specified, the Party referring a dispute to arbitration may, without the requirement of
                any further prior notice to the other Party, appoint its arbitrator as sole arbitrator and shall advise the other Party accordingly. The award of a sole arbitrator shall be binding on both Parties as if the sole arbitrator had been
                appointed by agreement.

            

    

     

    
      	20.6	
              In cases where neither the claim nor any counterclaim exceeds the sum of US$100,000 the arbitration shall be conducted in accordance with the LMAA Small Claims Procedure current at the time when the arbitration
                proceedings are commenced.

            

    

     

    
      	20.7	
              Notwithstanding the above, the Parties may agree at any time to refer to mediation any difference and/or dispute arising out of or in connection with this Agreement.

            

    

     

    
      	
              21.

            	
              Default Interest

            

    

     

    If Buyer shall fail to make payment within three (3) Banking Days of the due date of any sum of whatsoever nature payable by Buyer under this Agreement,
      Buyer shall be liable to pay default interest on such outstanding payment at the rate of [***]% above the interest rate then applicable to the Balance Payment as stated in Clause 3 (b).

     

    
      	
              22.

            	
              Assignment

            

    

     

    Seller shall have the right to assign the payments to be made by Buyer to Seller in respect of the Balance Payment and interest thereon and Clause 3.2
      (e) to any party or entity whatsoever. Save as stated, neither of the Parties shall have the right to assign this Agreement, without the prior written consent of the other Party.

    

    

    Sale and Purchase Agreement – Hull Number P[2053] 

    
      19

      
        
 

    

    
      	
              23.

            	
              Expenses/Activation Charges

            

    

     

    
      	(a)	
              In the event that Buyer does not remove the Rig from Seller’s shipyard within fourteen (14) days after delivery, Buyer shall be liable to pay the Seller costs and expenses incurred by Seller as a consequence of
                such non-removal including but not limited to preservation, maintenance, storage and insurance costs. The Parties will enter into an agreement to specifically regulate this.

            

    

     

    
      	(b)	
              All activation charges for the Rig shall be for Buyer’s account.

            

    

     

    	
             

          	
             

          	
             

          

     

    IN WITNESS WHEREOF the Parties hereto have hereunto executed this Agreement in two duplicate originals.

     

    	
            Signed by

          	
            )

          
	
            for and on behalf of

          	
            )

          
	
            PPL Shipyard Pte Ltd

          	
            )

          
	
            in the presence of;-

          	
            )

          

    

    

    	
            Signed by

          	
            )

          
	
            for and on behalf of

          	
            )

          
	
            Borr Jack-Up [●] Inc.

          	
            )

          
	
            in the presence of.-

          	
            )

          

    

    

    Sale and Purchase Agreement – Hull Number P[2053] 

    
      20

      
        
 

    

    EXHIBIT I

      COPY OF MASTER AGREEMENT

    

    

    Sale and Purchase Agreement – Hull Number P[2053] 

    
      21

      
        
 

    

    
    FORM OF CONSTRUCTION CONTRACT

    
      Page14

      
        
 

    

    
    SUBJECT TO CONTRACT

     

    Dated this ______ day of October 2017

     

    AGREED FORM OF

     

    RIG CONSTRUCTION CONTRACT

      (Pacific Class® 400 jack up drilling rig)

     

    Between

     

    BORR JACK-UP [ ] INC.

      (as “Buyer”)

     

    and

     

    PPL SHIPYARD PTE LTD

      (as “Builder”)

     

    PPL HULL NO. P[2047]

    

      

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047)

    
      Page 1 of 51

      
        
 

    

    RIG CONSTRUCTION CONTRACT

     

    This agreement for the construction, sale and purchase of a rig (the “Contract”) is made this ___________ day of October 2017

     

    BETWEEN

     

    BORR JACK-UP [ ] INC. incorporated in Marshall Islands and having its registered office at Thistle House, 4 Burnaby Street, Hamilton
      HM 11, Bermuda (hereinafter called “Buyer”).

     

    AND

     

    PPL SHIPYARD PTE LTD, a Singapore corporation, with its registered office situated at 21, Pandan Road, Singapore 609273 (hereinafter
      called “Builder”).

     

    WHEREAS

     

    
      	A.	
              Builder is willing to design, build, launch, equip, complete, commission, deliver and sell to Buyer at Builder’s shipyard a PPL Pacific ClassÒ 400 jack-up drilling unit (the “Rig”) as hereinafter described; and

            

    

     

    
      	B.	
              Buyer desires to purchase from Builder the Rig, take delivery and pay for it;

            

    

     

    all in accordance with the terms hereinafter set forth.

     

    NOW IT IS HEREBY AGREED AS FOLLOWS

    

    

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 2 of 51

      
        
 

    

    DEFINITIONS

    

    

    In this Contract the following words shall have the meanings set out herein below:-

     

    “Article or Articles” means the articles herein

     

    “Average LIBOR”, for any quarter after the Contract Delivery Date, shall mean the average of the Monthly LIBOR for the three (3)
      months of that quarter or in the event of early repayment of the balance of the purchase price of the Rig as stated in Article 3.2 by the Buyer, such average, as appropriately adjusted by the Builder.

     

    “Back End Fee” shall mean the sum payable by Buyer to Builder as stated in Clause 3(c).

     

    ““Banking Days” are days on which banks are open in London, Singapore, Oslo and in New York City and excluding days which are Saturday, Sunday or public holidays in any of
      the places listed above.

     

    “BFE” means any item, equipment, stores or services ordered directly by Builder from the manufacturer or supplier, which shall not be supplied and/or paid for by Buyer in
      accordance with the terms of the Contract.

     

    “Builder” means PPL SHIPYARD PTE LTD and inclusive of its servants and employee

     

    “Builder’s Guarantor” means Sembcorp Marine Ltd., a company incorporated in Singapore, who is the parent company of the Builder issuing the Builder’s Parent Company
      Guarantee.

     

    “Builder’s Parent Company Guarantee” means the parent company guarantee for payment of the First Payment as described in Clause 3.8 to be issued by the Builder’s Guarantor
      substantially in the form attached as Schedule 2 hereto.

    

    

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 3 of 51

      
        
 

    

    “Builder’s Representative” means the authorized representative appointed by Builder to act on its behalf pursuant to Article 9.6.

     

    “Buyer” means Borr Jack-Up [         ] Inc. and inclusive of its servants and employees.

     

    “Buyer’s Parent Company” means Borr Drilling Limited, a company incorporated in Bermuda, who is the parent company of the Buyer.

     

    “Buyer’s Parent Company Guarantee” means the parent company guarantee to be provided by the Buyer’s Parent Company substantially in the form attached as Schedule 3 hereto.

     

    “Buyer’s Representative” means the authorized representative appointed by Buyer pursuant to Article 9.1

     

    “Classification Society” or “Class” means the American Bureau of Shipping.

     

    “Contract” means the agreement of the parties set out in the Articles herein with its Annexure including Specifications and Drawings, and any amendments thereto.

     

    “Contract Delivery Date” means [11 September 2018][31 October 2018][30 January 2019].

     

    “Delivery and Acceptance” means the physical delivery of the Rig from the Builder to Buyer.

     

    “Delivery Date” means the Contract Delivery Date, as adjusted for Permissible Delay.

    

    

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 4 of 51

      
        
 

    

    “Effective Date” means the date when all the conditions under Article 28.2 are met.

     

    “Force Majeure” means the contingencies or circumstances described in Article 7.1.

     

    “Master Agreement” means an agreement dated [       ] October 2017 between the Builder and the Buyer, a copy of which is attached hereto as Exhibit 1

     

    “Monthly LIBOR” means the 3-month USD LIBOR as quoted in Bloomberg on the first New York banking day in a calendar month (or in the event the quotation from Bloomberg is
      not available, then the quotation from any other financial reporting service as the Builder shall determine), with the first Monthly LIBOR being determined as at the first New York banking day of the calendar month when delivery of the Rig takes
      place. If LIBOR should cease to be available, it shall be replaced by the reference rate which replaces LIBOR in the London interbank market, or such other rate as the Builder and the Buyer shall agree.

     

    “OEM” means original equipment manufacturers or vendors who supply any component or equipment forming part of the Rig.

     

    “OFE” means the equipment or materials furnished and delivered to Builder’s shipyard by Buyer for Builder to incorporate into the Rig and includes any equipment or
      materials ordered by the Builder on behalf of the Buyer pursuant to Clause 4.5 of the Master Agreement.

     

    “Permissible Delay” means all delays inclusive of Force Majeure Delay, causing delay in the delivery of the Rig which according to the terms of the Contract permit
      postponement of the Delivery Date.

     

    “Purchase Price” means the price stated in Article 3.1 and as adjusted in accordance with the terms of the Contract.

    

    

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 5 of 51

      
        
 

    

    “Rig” means the Pacific ClassÒ 400 jack-up drilling rig
      described in the Specifications.

     

    “Regulatory Bodies” means the relevant authority imposing rules and regulations with which the construction and delivery of the Rig must comply, which shall include the
      authorities of the State Flag together with other authorities set out in the Specifications.

     

    “Specifications” means the ______________ dated _________ in Annex A and the following:

     

    “State Flag” means the State referred to in Article 6.5.

     

    “Subcontractor” means any person (not being a servant or employee of the Builder) or company, with whom Builder has entered into contract for the design, construction,
      manufacture or supply of any item, equipment, work or service for the Rig.

     

    “Termination Notice” means the notice given by Builder pursuant to Article 24.2.

     

    “Variation” means any change, additions, deletions, alterations, substitution to the Works, or deviation from the Specifications.

     

    “Variation Order” means the agreement in writing executed by Buyer and Builder approving a Variation, in the form set out in Annex C as described in Article XIII
      (Variations).

     

    “Warranty Period” means the period of twelve (12) months after the Delivery and Acceptance of the Rig.

     

    “Works” shall have the meaning set out in Article 2.1

    

    

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 6 of 51

      
        
 

    

    ARTICLE 1

      

      SUBJECT OF THE CONTRACT

     

    
      	1.1	
              Builder agrees for the consideration and on the terms and conditions herein set forth, to design, construct, launch, equip, test and deliver in a good and workmanlike manner one (1) unit of Offshore Jack-up
                Drilling Rig (hereinafter called “Rig”) and bearing Builder’s Hull number of [P2047] for Buyer at one of the two Builder’s shipyards in Singapore, The Rig is to be constructed in conformity with the Contract and in accordance with the
                Specifications. The Rig is currently under construction and major equipment have been purchased.

            

    

     

    
      	1.2	
              Builder represents and warrants that it is duly authorized with all applicable licences and authorizations from any applicable governmental authority as may be required to design, engineer, build, launch, equip,
                complete, deliver and sell the Rig and perform in accordance with the Contract. The Builder shall be solely responsible for all aspects of the design and engineering required to build, launch, equip, complete and commission the Rig in
                accordance with the Contract.

            

    

     

    
      	1.3	
              At the time of delivery the Rig shall comply in all respects with its description in the Contract.

            

    

    

      Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047)

      

    
      Page 7 of 51

      
        
 

    

    ARTICLE 2

      

      DELIVERY FREE FROM CLAIMS AND LIENS/BUYER’S OBLIGATIONS

     

    
      	2.1	
              Builder agrees to perform all work necessary to design, construct, launch, equip, test, complete and commission and deliver and sell the Rig, in accordance with this Contract, and to deliver the Rig to Buyer free
                and clear of all liens, security, interests, claims and encumbrances (except for any liens or encumbrances on OFE provided by Buyer) afloat alongside Builder’s shipyard in Singapore, all of which are herein sometimes referred to generally
                as the “Works”.

            

    

     

    
      	2.2	
              Buyer shall be responsible for registration and documentation of the Rig in the name of Buyer at the Panama Register of Shipping and all expenses incurred with respect thereto shall be paid and be solely for the
                account of Buyer. In this regard, as soon as practicable after receipt of the First Payment, Builder shall forward copies of the Builder’s Certificate of the Rig duly notarised, the Class Attestation or Classification Certificate of the Rig
                and the Tonnage Attestation or Tonnage Certificate of the Rig (collectively “the Provisional Registration Documents”) to enable Buyer to provisionally register the Rig in their name at the Panama Register of Shipping. Buyer shall forward a
                copy of the provisional certificate of Panamanian registry of the Rig issued in their name to Builder not later than seven (7) days from the date of receipt by Buyer of the Provisional Registration Documents from Builder.

            

    

     

    
      	2.3	
              The Rig is presently built to the requirements of the Panama flag registry. Builder will inform Class of Buyer’s intent to register the Rig under the Panamanian ship registry. In the event that there is any work
                required to be carried out on the Rig to comply with the requirements of the Panamanian ship registry, such work shall be treated as variation order, and any cost and time impact on Contract Delivery Date shall be borne by Buyer.

            

    

     

    
      	2.4	
              Buyer shall within thirty (30) days after written request from the Builder, provide the complete information/documents listed in Schedule 1 hereto to Builder

            

    

    

    

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047)
    
      Page 8 of 51

      
        
 

    

    ARTICLE 3

      

      PURCHASE PRICE AND PAYMENT

     

    
      	3.1	
              In full payment for the Rig and as Builder’s compensation for designing, constructing, launching, equipping, testing, completing, commissioning, delivering and selling the Rig and in the performance of the Works,
                Buyer agrees to pay Builder a total consideration of United States Dollars One hundred and thirty-nine million five hundred thousand only (US$139,500,000 (hereinafter referred to as the “Purchase Price”) provided however that the Purchase
                Price shall be subject to adjustment in accordance with the provisions of Article 10 (Variations) and this Article 3 (Purchase Price and Payment).

            

    

     

    
      	3.2	
              The Purchase Price, shall be paid in full, free of bank charges, to Builder as follows:

            

    

     

    
      	

            	(a)	
              the sum of United States Dollars Fifty Five Million Eight Hundred Thousand( US$55,800,000) (“the First Payment”) not later than not later than fifteen (15) Banking Days from the Effective Date provided that the
                Builder’s Parent Company Guarantee has been issued by the Builder’s Guarantor in favour of the Buyer; and

            

    

     

    
      	

            	(b)	
              the balance of the Purchase Price amounting to United States Dollars Eighty three Million Seven Hundred Thousand] (US$83,700,000 (the “Balance Payment”) shall be made available as a seller’s credit, payable [***]
                the date falling 60 months from the date that Buyer actually takes delivery of the Rig. No balance of the Purchase Price is due if the Rig is not delivered under this Contract.

            

    

     

    If the Rig is delivered under this Contract, Buyer shall pay interest on the Balance Payment to Builder, quarterly, as follows:-

     

    
      	

            	(i)	
              during the period of 36 months after the Contract Delivery Date, at the rate of [***]% above the Average LIBOR up to the day the balance of the Purchase Price is paid to the Builder;

            

    

     

    
      	

            	(ii)	
              during the period of 12 months thereafter, at the rate of [***]% above the Average LIBOR up to the day the balance of the Purchase Price is paid to the Builder; and

            

    

     

    
      	

            	(iii)	
              during the period of 12 months thereafter, at the rate of [***]% above the Average LIBOR up to the day the balance of the Purchase Price is paid to the Builder.

            

    

     

    Builder shall invoice the Buyer in writing, for each quarter in respect of the interest payable for that quarter which interest shall be due and payable
      on the last Banking Day of that quarter. Builder’s invoices in this regard shall be conclusive evidence of such amount of Interest to be payable by Buyer, save for manifest error.

    

    

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 9 of 51

      
        
 

    

    For the purpose of clarification and avoidance of doubt, the accrual of the interest on the Balance Payment as provided above shall commence on the date
      on which the Rig is actually delivered to the Buyer. In the event Buyer takes delivery of the Rig later than the Contract Delivery Date, and such delay in taking delivery is not due to any delay on the part of Builder, the accrual of the interest on
      the Balance Payment as provided in this Clause shall commence on the Contract Delivery Date. In the event that the Buyer takes delivery earlier than the Delivery Date, the Balance Payment becomes due and interest starts to accrue on the Balance
      Payment from the actual delivery date.

     

    
      	3.3	
              Buyer shall fail to make payment within 7 Business Days of the due date of any sum of whatsoever nature payable by Buyer under this Contract, Buyer shall be liable to pay default interest on such outstanding
                payment at the rate of [***]% above the interest rate then applicable to the Balance Payment as stated in Article 3.2 hereinabove,

            

    

     

    
      	3.4	
              If the Builder fails to keep the Builders Parent Company Guarantee in force until delivery and acceptance of the Rig, the Builder shall be in breach of a condition of the Contract and the Buyer shall be entitled
                to terminate the Contract, in which event the First Payment together with interest at the rate of [***]% above the Average LIBOR calculated from the date of payment to the date of refund and all amounts paid by Buyer to Builder in respect
                of Variations as well as the cost of any OFE paid by Buyer (unless the OFE is delivered to Buyer) shall be immediately refunded and, until refunded in full are due as a debt by Builder to Buyer.

            

    

     

    
      	3.5	
              Buyer shall pay to Builder an amount to reflect the uplift in value of the Rig at the time when Buyer pays to Builder the Balance Payment, to be defined and calculated as follows:

            

    

     

    (A)          A definite fixed sum of USD[***];

     

    plus

     

    (B)          25% of the increase in value of the Rig obtained from the
        difference between:

     

    
      	

            	(1)	
              the average of 3 independent broker quotes for the value of the Rig at the time of Buyer’s payment of the Balance Payment, and

            

    

     

    
      	

            	(2)	
              the Purchase Price.

            

    

     

    Less

    
      

      

      
        	

              	(a)	
                [***]% per annum of the First Payment, calculated from the date of delivery of the Rig by the Builder to the Buyer until the date the Buyer pays the Builder the Balance Payment; and

              

      

       

      Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047)

      
        Page 10 of 51

        
          
 

      

    

    
      	

            	(b)	
              an amount equal to the interest accrued and/or paid by Buyer to Builder in respect of the Balance Payment.

            

    

     

    In the event that the average of the 3 independent broker quotes is lower than the Purchase Price, or If the amount to reflect the uplift in value of the
      Rig as calculated above results in a negative figure, then no amount in this sub-clause (B) will be payable by the Buyer, and the Builder has no obligation to reimburse the Buyer for the shortfall.

     

    
      	3.6	
              The Buyer shall during the period from the Effective Date up to 30 January 2019 (or such other date on which the last rig is delivered under the Master Agreement) place orders worth not less than US$[***] for
                equipment and spares for the Rig by executing and issuing purchase order forms to the Builder. The Buyer shall be liable to make an additional payment of [***]% on the value of such purchase orders as administrative charges. If the total
                value of Buyer’s orders by 30 January 2019 (or such other date on which the last rig is delivered under the Master Agreement) is less than US$[***], Buyer shall pay to Builder [***]% of the shortfall. Buyer shall make payment on its orders
                within 30 days from the date of Builder’s invoice.

            

    

     

    
      	3.7	
              All payments to be effected by Buyer to Builder pursuant to this Agreement shall be remitted to the following bank account of Builder, free and clear of bank charges;

            

    

     

    [***]

      Swift Address: [***]

      FED ABA: [***]

      For A/C: UOB Singapore

      Swift Code: [***]

      For Credit of PPL Shipyard Pte Ltd

      US$ current A/C No: [***]

     

    or to such other bank account as Builder shall notify Buyer in writing from time to time.

     

    
      	3.8	
              Payment by Buyer of the First Payment is conditional upon Builder providing Buyer with the Builder’s Parent Company Guarantee.

            

    

     

    
      	3.9	
              Buyer’s obligation to pay the Balance Payment (and any interest thereon) and Buyer’s obligation to pay the Back End Fee shall be secured by the Buyer’s Parent Company Guarantee from the Buyer’s Parent Company.

            

    

     

    
      
        	3.10	
                Buyer’s obligation to pay the Balance Payment (and any interest thereon) and Buyer’s obligation to pay the Back End Fee shall be secured by a first priority mortgage over the Rig and a first party assignment of the insurances and
                  requisition compensation of the Rig.

              

      

       

    

    
      Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047)

      
        Page 11 of 51

        
          
 

      

    

    
      	3.11	
              Builder shall have the right to assign its rights to receive repayment of the Balance Payment (and interest thereon) from the Buyer and its rights to receive payment of the Back End Fee from the Buyer, and in
                connection therewith, its rights to, and interests in the Buyer’s Parent Company Guarantee and the security documents as hereinafter defined in Article 6.8 to any third party including any financial institution with prior written consent of
                Buyer’s Parent Company, such consent not to be unreasonably withheld.

            

    

     

    
      	3.12	
              Buyer shall at its own cost on execution of this Contract provide Builder the Buyer’s Parent Company Guarantee from the Buyer’s Parent Company in respect of the performance of Buyer’s obligations under this
                Contract.

            

    

    

    
      

      

      Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047)

    

    
      Page 12 of 51

      
        
 

    

    ARTICLE 4

      

      CHANGE IN LAWS, RULES OR REGULATIONS

     

    
      	4.1	
              It is recognized that should any changes in any international or governmental laws, Regulatory Bodies, Class, rules or regulations be made subsequent to the date Builder made its request for class (“RFC Date”) for
                the Rig that make it necessary to modify the Specifications and/or detailed construction drawings for the Rig, such modifications shall be treated as a variation pursuant to Article 10 (Variations).

            

    

     

    
      	4.2	
              Builder shall notify Buyer of any applicable changes including the extension of time required, if any, to carry out such changes contemplated under this Article. Such changes shall be accepted by Buyer prior to
                implementation. In the event that Buyer does not accept such changes including the responsibility to pay Builder for the additional costs and/or the need to grant additional time to Builder as required pursuant to Article 10 (Variations),
                and such changes are required for the construction of the Rig in terms of its certification and compliance to this Contract, Builder shall not proceed with the Variation and be relieved and absolved from any responsibility and the
                consequences arising there from shall be solely with Buyer

            

    

    

      Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047)

    

    
      Page 13 of 51

      
        
 

    

    ARTICLE 5

      

      PROPERTY/TOTAL LOSS

     

    
      	5.1	
              The Rig including all materials purchased and/or delivered to Builder’s shipyard or incorporated in the Rig shall at all times until Delivery and Acceptance of the Rig be the property of Builder. OFE shall become
                the property of Builder when it is installed or incorporated in the Rig.

            

    

     

    Risk for loss or damage to the Rig shall remain with Builder until Delivery and Acceptance of the Rig pursuant to Article 6 (Delivery).

     

    Title to and risk for loss or damage to the Rig shall pass to the Buyer upon Delivery and Acceptance thereof by Buyer.

     

    
      	5.2	
              Should the Rig become an actual, constructive or compromised total loss before delivery, the First Payment together with interest at the rate of [***]% above the Average LIBOR calculated from the date of payment
                to the date of refund and all amounts paid by Buyer to Builder in respect of Variations as well as the cost of any OFE paid by Buyer (unless the OFE is delivered to Buyer) shall be refunded by Builder to Buyer and this Contract shall be
                terminated and neither Party hereto shall have any claims against the other Party pursuant to, or in connection with, this Contract other than accrued claims.

            

    

     

    
      	5.3	
              Prior to the commencement of the Works and until the Delivery of the Rig, Builder shall, at its cost and expense, carry and maintain insurance policies with reputable insurance companies for the types of insurance
                described below:

            

    

     

    
      	

            	(a)	
              Work Injury Compensation Insurance and Employers Liability Insurance in accordance with Singapore law

            

    

     

    
      	

            	(b)	
              General Third Party Liability Insurance for death, bodily Injury or property damage.

            

    

     

    
      	

            	(c)	
              Construction Risks Insurance in an amount equal to the Purchase Price for loss or damage to the Rig and all machinery, materials and equipment forming part of or intended to be incorporated into the Rig from the
                time they are delivered to the Builder’s yard.

            

    

     

    
      	5.4	
              The Construction Risks Insurance shall (1) be taken out in the name of Builder as the principal assured and include Buyer as an additional or other assured; (2) provide that it will not be cancelled or its
                coverage reduced except upon twenty (20) days prior written notice to Buyer; and (3) contain waiver of subrogation provisions pursuant to which the insurer waives rights of subrogation against Builder and Buyer

            

    

    

      Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047)

      
        Page 14 of 51

        
          
 

      

    

    ARTICLE 6

      

      DELIVERY

     

    
      	6.1	
              The Rig shall be delivered by Builder and accepted by Buyer in accordance with this Article 6 (Delivery). Before Buyer accepts delivery of the Rig, the Rig shall have been classed by the Classification Society (as
                evidenced by the attainment by Builder of an interim classification certificate).

            

    

     

    
      	6.2	
              Delivery of the Rig shall be on the Delivery Date.

            

    

     

    
      	6.3	
              The Rig shall be ready for delivery when Builder has secured the interim classification certificate.

            

    

     

    
      	6.4	
              To effect Delivery and Acceptance by Builder and Buyer of the Rig, Builder and Buyer shall perform the following:

            

    

     

    
      	

            	(a)	
              Buyer shall provide to Builder a power of attorney (acceptable to Builder) authorizing a person or persons to accept delivery of the Rig for and on behalf of Buyer together with the Acceptance of Sale of the Rig,
                in the requisite Panamanian format, duly notarised [In Singapore].

            

    

     

    
      	

            	(b)	
              Builder shall concurrently release the original Bill of Sale duly notarised, and the Builder’s Certificate duly notarised, to Buyer.

            

    

     

    
      	

            	(c)	
              Upon Delivery and Acceptance of the Rig, Builder shall deliver to Buyer the documents listed in Annex F.

            

    

     

    Builder shall deliver to Buyer the Rig afloat, at Builder’s shipyard.

     

    
      	6.5	
              Builder shall provide, deliver and pay for all certificates necessary for the approval of the Rig, as further set out in the Contract, together with all documents reasonably required by Buyer for the registration
                of the Rig in Panama (Flag State).

            

    

     

    
      	6.6	
              If original certificates are not obtainable at the time of delivery of the Rig, Builder shall furnish Buyer with provisional or interim certificates, and as soon as practicable after delivery, Builder shall submit
                the original certificates to Buyer.

            

    

     

    
      
        	6.7	
                Buyer shall take possession of the Rig immediately upon Delivery and Acceptance thereof, and shall remove the Rig from the premises of Builder within fourteen (14) days after the Delivery and Acceptance as aforesaid. If Buyer does not
                  remove the Rig within the said period, Buyer shall thereafter pay the Builder costs and expenses Incurred by Builder as a consequence of such non-removal including but not limited to preservation, maintenance, storage and Insurance costs.

              

      

       

    

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047)

    
      Page 15 of 51

      
        
 

    

    
      	6.8	
              As security for the due fulfilment of the Buyer’s obligations to pay the Balance Payment to the Builder pursuant to this Contract, Buyer shall, forthwith upon delivery of the Rig to it pursuant to this Contract,
                execute a first preferred Panamanian naval mortgage of the Rig (in such number of sets as required by the Builder) together with any accompanying registration form or memorandum of particulars as required by the Panama Register of Shipping
                and a deed of assignment of the insurances and requisition compensation of the Rig in favour of Builder (collectively “the Security Documents”). Builder shall, at Buyer’s cost, cause the title to the Rig and the said first priority naval
                mortgage of the Rig (together with any accompanying registration form or memorandum of particulars (Evidence of Authority) as required by the Panama Register of Shipping) to be registered with the Panama Register of Shipping.

            

    

     

    Concurrently with the execution of the Security Documents, Buyer shall deliver to Builder the original hull and machinery, increased value and excess
      disbursements (if any) and war risks (if any) insurance policies of the Rig, together with a copy of the P&I Certificate of Insurance or Certificate of Entry of the Rig and such other documents as Builder shall reasonably require. Buyer shall
      also notify Builder of the name and contact details of the Rig’s insurance brokers forthwith upon Builder’s request.

     

    
      	6.9	
              In the event the Rig is damaged due to any reason whatsoever prior to the Delivery Date and written notice thereof has been given to Buyer, Buyer shall only be entitled to cancel this Contract in the event Builder
                is unable to rectify the damage and deliver the Rig to Buyer in such conditions as required under this Contract within 210 days of the event causing the damage. Builder has 210 days to rectify the damage. If this period extends beyond the
                Delivery Date, the Buyer shall not be entitled to terminate for late delivery until such period has expired. This clause does not apply in the events where the Rig becomes an actual, constructive or compromised total loss before delivery.

            

    

     

    
      	6.10	
              In the event Buyer takes delivery of the Rig later than the Delivery Date, and such delay in taking delivery is not due to any delay on the part of Seller, Buyer shall compensate Seller for the additional costs to
                keep the Rig at Seller’s yard, including but not limited to the costs of preservation, maintenance, storage and insurance for the Rig.

            

    

    

    

  

  Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047)
    
      Page 16 of 51

      
        
 

    

    ARTICLE 7

      

      FORCE MAJEURE AND PERMISSIBLE DELAYS

     

    
      	7.1	
              If, at any time before the delivery and acceptance of the Rig, either the construction of the Rig or any performance required under the provisions of this Contract and the Specifications as a prerequisite of
                delivery of the Rig is delayed due to war, blockade, revolution, insurrections, civil commotions, riots, strikes, sabotage, terrorism, lockouts, plague or other epidemics, quarantines, prolonged failure, shortage or restriction of electric
                current, or import/export embargoes, fires, accidents or stop work orders imposed by any government; or due to acts of God including, but not limited to, earthquakes, tidal waves, or typhoons (except in the case of each of the foregoing if
                they are weather conditions which are normal occurrences for the time of year and can reasonably be expected); or by damage or destruction of the shipyard or Works of Builder or its Subcontractors or of the Rig, or any part thereof, by
                fire, flood, or other causes beyond the control of Builder or its Subcontractors; or by delay in the delivery of machinery, equipment or materials provided they shall have been ordered in time by Builder, or any and all occurrences and/or
                causes not within the control of Builder or its Subcontractors that delay or hinder the performance of Builder and which Builder, by the exercise of due diligence would not have been able to avoid or overcome, each of such contingencies
                shall be considered an event of Force Majeure as used in this Contract, and in the event of delays due to the happening of any of the aforementioned contingencies, the Delivery Date shall be extended by the number of days corresponding to
                the net delay In delivery caused thereby. It is agreed, however, that Builder shall make all reasonable efforts to minimize the delays caused by Force Majeure.

            

    

     

    
      	7.2	
              Delays on account of such causes as specified in Article 7.1 or by reason of a breach or an act of prevention by Buyer, or any other delay of a nature which under the terms of this Contract {including but not
                limited to Articles 4 (Change in Laws, Rules or Regulations), 7 (Force Majeure and Permissible Delays), 10 (Variations), and 25 (Compliance with Laws)} permits postponement of the Delivery Date shall constitute Permissible Delays and shall
                extend the Delivery Date for any net delay caused thereby.

            

    

     

    
      	7.3	
              All other delays shall be considered as non-permissible and unauthorized delays.

            

    

     

    
      	7.4	
              Within twenty one (21) days after the date of occurrence of any cause of delay, on account of which Builder claims that it is entitled under this Contract to a postponement of the Delivery Date, Builder shall
                notify Buyer in writing of the date such cause of delay occurred and the reasons therefore. Likewise, within twenty one (21) days after the date of ending of such cause of delay, Builder shall notify Buyer of the date such cause of delay
                ended. Builder shall also notify Buyer of the maximum time period by which the time of delivery is postponed by reason of such cause of delay, with all reasonable dispatch and with reasonable evidence to justify the delay, after such cause
                of delay has ended. Buyer shall upon receipt of any such notification from Builder provide its comments and reasons for objection if any, within twenty one (21) days, and if no such comments or reasons for objection are received by Builder,
                Buyer shall be deemed to have accepted Builder’s claim for postponement of the Delivery Date.

            

    

    
      Page 17 of 51

      
        
 

    

    2.     Failure of Buyer to object to Builder’s claim for postponement of
        the Delivery Date within twenty one (21) days after receipt by Buyer of such notice of claim shall be deemed to be a waiver by Buyer of its right to object to such postponement of the Delivery Date. Failure by the Builder to notify the Buyer in
        accordance with this Article 7.2 shall bar the Builder from claiming any extension on the basis of Force Majeure.

     

    
      	7.5	
              Buyer shall not be entitled to use any of the Force Majeure events to delay or avoid its obligation to pay moneys due to Builder under this Contract.

            

    

    

      Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047)

      

    
      Page 18 of 51

      
        
 

    

    ARTICLE 8

      

      DAMAGES FOR DELAYS

     

    
      	8.1	
              Builder agrees to prosecute the Works diligently in an expeditious and workmanlike manner. Builder agrees that subject to the provisions of this Contract (including but not limited to Articles 4 (Change in Laws,
                Rules and Regulations), 7 (Force Majeure and Permissible Delays), and 10 (Variations)), or by reason of any default in performance or any act of prevention or breach of this Contract by Buyer, it shall make delivery of the Rig on the
                Delivery Date.

            

    

     

    
      	8.2	
              in the event that Buyer has a charter for the Rig and if the delivery of the Rig is delayed beyond the Delivery Date, then Builder shall pay to Buyer as liquidated and agreed damages, the amount of United States
                Dollars Twenty Thousand Dollars (US$20,000.00) per day for each and every day the delivery of the Rig is so delayed more than sixty (60) days (grace period) beyond the said Delivery Date, subject to a maximum of United States Dollars: Two
                Million Only (US$2,000,000.00). Such liquidated damages shall be Buyer’s sole and exclusive remedy for delay in the delivery of the Rig and shall be in lieu of all losses or damages, which Buyer may suffer or incur by reason of such delay,
                it being further understood and agreed that, except where expressly provided in this Contract or where due to willful misconduct on the part of the Builder’s senior management, Builder shall not be responsible or liable to Buyer or any
                third party for any direct, indirect and/or consequential loss or damages (including but not limited to loss of use of the Rig, loss of time, loss of production, loss of profit or earnings, financing costs, loss of other contracts etc.),
                occasioned by delay in the delivery of the Rig, except for such aforementioned liquidated damages.

            

    

     

    
      	8.3	
              Deficiency in variable Loads:

            

    

     

    Pursuant to the Specifications, the Jacking Variable Load shall be 2,268 metric tons (“MT”), the Drilling Variable Load shall be 3,401 MT, and the
      Floating Variable Load shall be 2,268 MT. The Jacking Variable Load, the Drilling Variable Load, and the Floating Variable Load are hereafter also referred jointly or separately as the “Variable Loads”.

     

    If either one or more of the Variable Loads are not achieved, the Purchase Price may, subject to the decision of Buyer and as an alternative to Buyer
      requiring the deficiency to be remedied, be reduced as follows:

     

    
      	

            	(a)	
              For each full MT reduction in the Floating Variable Load of more than 100MT but maximum 200MT, a reduction of the Purchase Price with US$15,000 per MT of reduced capacity after giving an allowance to Builder of
                100MT,

            

    

     

    
      
        	

              	(b)	
                For each full MT reduction in the Jacking Variable Load of more than 100MT but maximum 200MT, a reduction of the Purchase Price with US$15,000 per MT of reduced capacity after giving an allowance to Builder of 100MT.

              

      

       

    

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047)

    
      Page 19 of 51

      
        
 

    

    
      	

            	(c)	
              For each full MT reduction in the Drilling Variable Load of more than 100MT but maximum 200MT, a reduction of the Purchase Price with US$15,000 per MT of reduced capacity after giving an allowance to Builder of
                100MT.

            

    

     

    
      	

            	(d)	
              The reductions pursuant to (a) to (c) above are not mutually exclusive. The total reduction of the Purchase Price pursuant to this Article shall in any event not exceed US$2,250,000.

            

    

     

    Every and all downward adjustments of the Purchase Price provided in this Article shall be made by Builder by way of a set off against the balance of the
      Purchase Price due to Builder on delivery of the Rig.

    

    

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 20 of 51

      
        
 

    

    ARTICLE 9

      

      BUYER’S REPRESENTATIVE AND BUILDER’S REPRESENTATIVE

     

    
      	9.1	
              Within fourteen (14) days of the Effective Date as described in Article 28 (Effective Date of Contract), Buyer shall appoint and notify Builder in writing the name of Buyer’s Representative. Buyer may from time to
                time appoint some other person as Buyer’s Representative in place of the person previously so appointed and shall give notice in writing of the name of such other person to Builder without delay. Such appointment shall be made at such a
                time and in such a manner as to mitigate as far as possible any adverse effect on the progress of the Works. Such appointment shall only take effect upon receipt of such notice in writing by Builder.

            

    

     

    
      	9.2	
              Buyer’s Representative shall represent and act for Buyer at all times during the currency of this Contract. All notices, instructions, orders, approvals and all other communications under the Contract shall be
                given by Buyer’s Representative, except as herein otherwise provided. All notices, instructions, information and other communications given by Builder to Buyer under the Contract shall be given to Buyer’s Representative, except as herein
                otherwise provided.

            

    

     

    
      	9.3	
              Buyer may send to and maintain at Builder’s shipyard, at its own cost and expense, one or more representatives, but only one of whom shall be duly authorized in writing by Buyer to Builder to be Buyer’s
                Representative to act on behalf of Buyer

            

    

     

    
      	
              9.4

            	
              Buyer undertakes that         it shall ensure that the Buyer’s Representative and its other representatives carry out their duties in accordance with standard rig building practice and in such a way as to
                avoid any unnecessary increase in building cost, delay to the construction and delivery of the Rig, and/or disturbance to the construction schedule of Builder.

            

    

     

    
      	9.5	
              At all times during the construction of the Rig, Builder shall:

            

    

     

    
      	

            	(a)	
              afford the Buyer’s Representative full access to Builder’s shipyard and shall use its best efforts to secure access to the shipyards of its subcontractors, to view the progress of the construction;

            

    

     

    
      	

            	(b)	
              provide Buyer’s Representative with separate air-conditioned working office space complete with desks; furniture; cupboards; meeting rooms; common photocopy machine; telephone; facsimile machine; at no extra cost
                in Builder’s shipyard, as provided in the Specifications (the costs for usage of telephone and facsimile shall be paid by Buyer); and

            

    

     

    
      
        	

              	(c)	
                cooperate with Buyer’s Representative so as to keep him informed as to the progress of the Works.

              

      

       

      Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047)

      
        Page 21 of 51

        
          
 

      

      
        	9.6	
                Within fourteen (14) days of the Effective Date as described in Article 28 (Effective Date of Contract), Builder shall appoint Builder’s Representative. Builder may from time to time appoint some other person as Builder’s
                  Representative in place of the person previously so appointed and shall give notice in writing of the name of such other person to Buyer without delay. Such appointment shall be made at such a time and in such a manner as to mitigate as
                  far as possible any adverse effect on the progress of the Works. Such appointment shall only take effect upon receipt of such notice in writing by Buyer.

              

      

    

    

    

    

    
      	9.7	
              Builder’s Representative shall represent and act for Builder at all times during the currency of this Contract and shall give to Buyer all Builder’s notices, Information and all other communications under the
                Contract. All notices, instructions, information and other communications given by Buyer to Builder under the Contract shall be given to Builder’s Representative, except as herein otherwise provided. No failure by the Buyer or the Buyer’s
                Representative to discover or notify a non-conformity shall relieve the Builder of any of its obligations under this Contract nor entitle the Builder to any compensation or postponement of the Delivery Date.

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 22 of 51

      
        
 

    

    ARTICLE 10

      

      VARIATIONS

     

    
      	10.1	
              All Works shall be performed in accordance with the Contract, except as it may be modified in the Specifications to reflect the changes as herein provided.

            

    

     

    Without invalidating this Contract, Buyer may request in writing Variations by altering, adding to or deducting from the Works to be performed by Builder
      hereunder as it is delineated in the Specifications. Notwithstanding the foregoing, it is, however, agreed that no change or variation shall be made or allowed to the following:

     

    
      	

            	(a)	
              general dimension of the Rig as described in Section 1.02 (General Description) of the Specifications; and

            

    

     

    
      	

            	(b)	
              items in Section 3.0 (Design and Performance Data) of the Specifications.

            

    

     

    Builder may also propose in writing to Buyer any modification to the Specifications, which in Builder’s opinion will improve the quality, efficiency,
      functionality, and design of the Rig, or the bringing forward of the Delivery Date. Buyer may at its discretion approve or reject Builder’s proposed modifications, and if approved by Buyer, Buyer shall request Builder in writing to proceed with
      Variation as aforementioned and pursuant to this Article.

     

    
      	10.2	
              Upon receiving a written request for Variation from Buyer. if the Variation so requested can be reasonably undertaken having regard to the stage of construction of the Rig, Builder’s and its subcontractors’ work
                schedule, and Builder’s other commitments at the shipyard, then Builder will advise Buyer in writing within twenty one (21) working days a quotation of the change in the Purchase Price and/or Delivery Date (if any) as a result of
                alterations and adjustments required to the Specifications. In particular, after launching of the Rig, Builder has a right in its sole discretion to reject a Variation requested by Buyer which would substantially affect Builder’s work
                schedule and/or Builder’s other commitments at the shipyard.

            

    

     

    
      	10.3	
              Builder may at any time raise a Variation request to Buyer in writing to issue a Variation Order when comments, remarks, amendments or instructions which Buyer may require Builder to carry out, which in Builder’s
                opinion constitute a Variation, detailing with supporting documents, the change in the Purchase Price and/or Delivery Date, and reasons for Builder considering such comments, remarks, amendments or instructions amounting to Variations.

            

    

     

    
      	10.4	
              if any Variation, modification or revision is compulsory for the Rig and its Class, either party shall, upon receipt of such information from the Classification Society or such other Regulatory Bodies, promptly
                notify the other party in writing, and Builder shall thereupon incorporate such alterations or changes into the Works, subject to the execution of a Variation Order. Any changes required by the Classification Society or regulatory bodies
                following revisions to the requirements of the Classification Society or Regulatory Bodies which occur after the RFC Date shall be for Buyer’s account.

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 23 of 51

      
        
 

    

    
      	10.5	
              If such amendments, modifications or revisions are not compulsory for the Rig or its classification, but Buyer desires to incorporate such amendments, modifications or revisions into the Specifications or the
                Works, then Buyer shall notify Builder and Builder shall proceed to perform such amendments, modifications, or revisions, subject to the execution of a Variation Order addressing appropriate adjustments (if any) to the Purchase Price,
                Delivery Date (based on the principles set out in Article 10.2) and/or any other provisions of this Contract. The costs and expenses incurred by Builder for such amendments, modifications or revisions shall be for Buyer’s account.

            

    

     

    
      	10.6	
              For all Variation, the adjustment to the Purchase Price and time for delivery shall be as follows:

            

    

     

    
      	

            	(a)	
              based on a fair and reasonable agreed lump sum price and time extension to the Delivery Date, if any; or

            

    

     

    
      	

            	(b)	
              based on the Schedule of Rates (Annex B) and an agreed time extension to the Delivery Date, if any.

            

    

     

    
      	10.7	
              No Variation shall be made and no additional work shall be performed by Builder until the change in or addition to the work and the adjustments, if any, in the Purchase Price and/or Delivery Date occasioned
                thereby, have been agreed in writing in a Variation Order in the form set out in Annex C, and signed for identification by authorized representatives of both parties. Such adjustments in the Purchase Price and/or the Delivery Date shall be
                negotiated in good faith between Buyer and Builder.

            

    

     

    
      	10.8	
              Payment for Variation pursuant to this Article 10 (Variations) shall be paid within thirty (30) days from Builder’s invoice, or as agreed in the Variation Order

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 24 of 51

      
        
 

    

    ARTICLE 11

      

      BUYER’S SERVANTS AND REPRESENTATIVE

     

    
      	11.1	
              If Buyer should desire to have any third party or its representatives come into Builder’s and/or Builder’s subcontractor’s shipyard to inspect or assist Buyer in the performance of any work, Builder may impose on
                Buyer reasonable requirements with regard to said third party’s or Buyer’s representatives’ insurance coverage as a condition for admittance to Builder’s and/or Builder’s subcontractor’s shipyard. Buyer shall bear full responsibility for
                such third party or Buyer’s representatives and for their acts while in Builder’s and/or Builder’s subcontractor’s shipyard.

            

    

     

    
      	11.2	
              Buyer shall be liable for and shall defend, indemnify and hold harmless Builder against any loss of and/or damage to property and/or injury to or death of any third party (which are not already included in Article
                21 Builder’s and Buyer’s Indemnities) where such loss of and/or damage to property and/or injury to and/or death of such third party is howsoever caused by Buyer.

            

    

     

    
      	11.3	
              Builder shall be liable for and shall defend, indemnify and hold harmless Buyer against any loss of and/or damage to property and/or injury to or death of any third party (which are not already included in Article
                21 Builder’s and Buyer’s Indemnities) where such loss of and/or damage to property and/or injury to and/or death of such third party is howsoever caused by Builder

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 25 of 51

      
        
 

    

    ARTICLE 12

      

      WARRANTIES

     

    
      	12.1	
              Builder warrants that the workmanship employed in the construction of the Rig shall be free from defects and shall comply with this Contract.

            

    

     

    
      	12.2	
              The foregoing warranty of Builder shall be for a period of twelve (12) months (“Warranty Periods”) after the delivery by Builder and acceptance by Buyer of the completed Rig.

            

    

     

    
      	12.3	
              If at any time during the Warranty Period, the Rig’s workmanship is defective or found not to comply with the foregoing warranty of Builder, Buyer shall give Builder written notice thereof within fourteen (14)
                days after Buyer’s discovery of such failure to comply, and Builder shall promptly upon receiving such notice, and at Builder’s cost and expense, repair or replace the same in good and proper operating condition sufficient to meet the
                requirements of this Contract and of Builder’s said warranties hereunder. Builder shall have no obligation to Buyer for any defects discovered or notified subsequent to the expiry of the Warranty Period.

            

    

     

    
      	12.4	
              Any repair or replacement to be carried out by Builder will be treated as priority by Builder and, if possible, be performed while the Rig is on location or at such other points as may be designated by Buyer.
                Builder shall not be responsible for the following cost: transport of personnel to and from nearest port to the rig, food and accommodation for personnel on board the rig, cost of underwater
                divers, if any. However, if Builder shall advise Buyer in writing that such repair or replacement can be made only in Builder’s shipyard, then Buyer shall either return the Rig (or the part or item affected where feasible to detach from the
                Rig) at Buyer’s sole cost to Builder’s shipyard for such repair or replacement, or advise Builder in writing that it is not convenient for Buyer to so return the Rig or component to Builder’s shipyard, in which later event Builder shall pay
                to Buyer an amount, in lieu of Builder’s making said repair or replacement, equal to the reasonable cost to Buyer of effecting such repair or replacement which cost shall be evidenced by invoice or other written evidence, provided always
                that Buyer must obtain Builder’s prior consent if it wants to undertake the repair or replacement work itself or by third parties, and Builder shall not be responsible for such work, and provided always that Buyer shall in all circumstances
                be responsible for the cost of mobilization and transport of the Rig from location to any yard or site, and the cost of dry docking in other yards, if any.

            

    

     

    
      	12.5	
              For component or equipment manufactured by OEM installed or incorporated in the Rig, the warranty provided herein by Builder to Buyer shall be identical to that provided by OEM to Builder. Builder shall assign to
                Buyer all its rights to these warranties from OEM, which have not expired, on the delivery of the Rig and Buyer shall seek its remedies or enforce its rights against the OEM in the event of a warranty claim in respect of such warranties
                which have been assigned to it at its sole cost and expense.

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 26 of 51

      
        
 

    

    
      	12.6	
              The foregoing warranties are in lieu of all other warranties and/or guarantees and no other warranties and/or guarantees expressed, implied or statutory are given by Builder by virtue of this Contract. The
                obligations of Builder to Buyer set forth in this Article are the exclusive liabilities of Builder to Buyer for any defects in workmanship and material incorporated in the Rig under the Contract, and Builder shall not be liable to Buyer for
                any negligence or strict liability, or otherwise in respect of said workmanship and material. Builder shall not be responsible or liable for any defects whatsoever other than the defects specified in this Article. No employee or
                representative of Builder is authorized to change this warranty in any way or grant any other warranty.

            

    

     

    
      	12.7	
              Builder shall not be responsible for any defects in any part of the Rig which have been caused subsequent to delivery of the Rig by any replacement or repair work performed by Buyer or any other contractor, or for
                any defects to the extent the same have been caused by use in excess of specified design limitations or improper maintenance of the Rig on the part of Buyer, its servants or agents or by ordinary wear and tear.

            

    

     

    
      	12.8	
              Except in the case of willful misconduct on the part of the Builder’s senior management, Builder shall in all circumstances not be responsible or liable for any consequential or special losses, damages or expenses
                (including but not limited to loss of use of the Rig, loss of time, loss of production, loss of profit or earnings, financing costs, loss of other contracts etc.), directly or indirectly howsoever occasioned by Buyer or any third party due
                to defects specified in this Article, or due to repairs or other work done to remedy such defects, or as a result of the failure of any work or item of material or equipment to meet the above stated warranties of Builder

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 27 of 51

      
        
 

    

    ARTICLE 13

      

      TAXES AND CHARGES

     

    
      	13.1	
              Builder shall pay (without seeking any reimbursement whatsoever from Buyer) all import, export, excise or other taxes, duties and charges, including VAT and GST (“Taxes”) which may be levied or imposed on Builder
                by the authorities or government in Singapore or elsewhere in connection with the execution and/or performance of all work by Builder or its subcontractors or suppliers under this Contract up to delivery and acceptance of the Rig to Buyer.
                Buyer shall bear and pay any other Taxes (except for income taxes of Builder) which may be levied or assessed on Buyer outside Singapore in connection with the execution and performance of this Contract except for Taxes imposed upon items
                to be procured by the Builder under this Contract. Any taxes, fees and expenses imposed on Buyer in connection with the purchase and registration of the Rig in Buyer’s nominated flag state shall be for Buyer’s account.

            

    

     

    
      	13.2	
              In the event that one party to this Contract (“Party A”) is obliged to make payment as a result of the failure of the other party to this Contract (“Party B”) to comply with its obligations under Article 13.1,
                Party B shall fully indemnify Party A upon Party A’s written demand, in respect of all costs which are incurred as a result of Party B’s failure to pay any such Taxes.

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 28 of 51

      
        
 

    

    ARTICLE 14

      

      DOCUMENTS TO BE FURNISHED

     

    
      	14.1	
              Upon acceptance of the Rig by Buyer, Builder shall at its cost furnish all detailed construction drawings such as: general arrangement, structural, mechanical, piping system, electrical system and outfitting
                drawings, plus drawing indexes, corrected to agree with the completed construction of the Rig to Buyer for use by Buyer or its successors or assigns, to be used for the purposes herein designated. Buyer agrees that it shall not release any
                such information to third parties, except as needed for specific purposes connected with the sale, lease, use, operation, maintenance and repair of the Rig, and review by governmental authorities or underwriters or in accordance with the
                regulations of any securities exchange. Notwithstanding the generality of the foregoing, it is agreed that Builder shall not be obliged to provide to Buyer any proprietary information relating to the design of the Rig.

            

    

     

    
      	14.2	
              Builder further agrees to deliver or cause to be delivered to Buyer upon acceptance of the Rig by Buyer all necessary certificates, either final, if available or preliminary (if final not available), to clear the
                Rig through customs and administrative authorities. All fees in respect of the classification and survey of the Rig by the Classification Society shall be paid by Builder. Builder will furnish Buyer with copies of all significant
                correspondence and documents relating to these classification and survey save for any proprietary and confidential information relating to the design of the Rig.

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 29 of 51

      
        
 

    

    ARTICLE 15

      

      CONFLICTS BETWEEN CONTRACT, SPECIFICATIONS AND CONTRACT DRAWINGS

     

    
      	15.1	
              The intention of the parties is that the provisions of these Articles and the Specifications are meant to supplement each other and be read and interpreted as a whole.

            

    

     

    However, in the event there is any conflict between any of the provisions in the Articles herein and the Specifications, the provisions of the Articles
      shall prevail.

     

    In the event there is any conflict between the Specifications and the Drawings included in the Specifications, the Specifications shall prevail over the
      Drawings.

     

    In the event of any conflict between any of the Drawings, the later in date shall prevail.

     

    In the event of any disputes as to conformity with Classification Society Rules, the decision of the surveyor of the Classification Society shall be
      final.

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 30 of 51

      
        
 

    

    ARTICLE 16

      

      GOVERNING LAW AND DISPUTE RESOLUTION

     

     

    
      	16.1	
              This Contract shall be governed and construed by and in accordance with English law.

            

    

     

    
      	16.2	
              If any dispute between Buyer and Builder arises as to any matter arising under or out of or in connection with this Contract or the carrying out of work under this Contract, the parties shall in the first instance
                attempt to settle the dispute amicably by reference of the dispute to the senior management of the parties for negotiation and resolution.

            

    

     

    
      	16.3	
              If the dispute remains unresolved within a fourteen (14) days period from the commencement of such negotiation, it shall be referred to arbitration in London in accordance with the Arbitration Act 1996 or any
                statutory modification or re-enactment thereof save to the extent necessary to give effect to the provisions of this Clause.

            

    

     

    
      	16.4	
              The arbitration shall be conducted in accordance with the London Maritime Arbitrators Association (LMAA) Terms current at the time when the arbitration proceedings are commenced.

            

    

     

    The reference shall be to three arbitrators. A party wishing to refer a dispute to arbitration shall appoint its arbitrator and send notice of such
      appointment in writing to the other party requiring the other party to appoint its own arbitrator within fourteen (14) calendar days of that notice and stating that it will appoint its arbitrator as sole arbitrator unless the other party appoints its
      own and gives notice that it has done so within the fourteen (14) days specified. If the other party does not appoint its own arbitrator and give notice that it has done so within the fourteen (14) days specified, the party referring a dispute to
      arbitration may, without the requirement of any further prior notice to the other party, appoint its arbitrator as sole arbitrator and shall advise the other party accordingly. The award of a sole arbitrator shall be binding on both Parties as if the
      sole arbitrator had been appointed by agreement.

     

    In cases where neither the claim nor any counterclaim exceeds the sum of USD100,000 the arbitration shall be conducted in accordance with the LMAA Small
      Claims Procedure current at the time when the arbitration proceedings are commenced.

     

    Notwithstanding the above, the Parties may agree at any time to refer to mediation any difference and/or dispute arising out of or in connection with
      this Agreement.

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 31 of 51

      
        
 

    

    ARTICLE 17

      

      TECHNICAL DISPUTES

     

    
      	17.1	
              In the event that a difference of opinion between Buyer and Builder arises concerning any technical matters under this Contract, or in respect of material or workmanship affecting the classification of the Rig,
                Builder and Buyer agree to be bound by the decision of the surveyor of the Classification Society. The decision of the surveyor of the Classification Society shall be final and binding upon the parties and shall be given within thirty (30)
                days of receipt of parties’ statements of position.

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 32 of 51

      
        
 

    

    ARTICLE 18

      

      SUBCONTRACTING AND SUPPLY

     

    
      	18.1	
              Without in any manner prejudicing the rights and obligations of Builder and Buyer hereunder, it is acknowledged and agreed by Buyer that:

            

    

     

    
      	

            	(i)	
              Builder may cause part of the Works to be performed by one or more subcontractors without the prior written consent of the Buyer; and

            

    

     

    
      	

            	(ii)	
              Builder shall have the discretion to select appropriate component and equipment for the Rig from OEM.

            

    

     

    Builder shall keep Buyer informed of all new major subcontract work to be performed, and Builder shall use due care to select competent and efficient
      subcontractors and OEM. Builder shall be fully responsible for the performance of all subcontractors and any segment of the Works performed by such subcontractors so that all production milestones and quality requirements are met.

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 33 of 51

      
        
 

    

    ARTICLE 19

      

      ASSIGNMENT

     

    
      	19.1	
              The Builder shall have the right, by giving prior notice to the Buyer to assign the payments to be made by the Buyer to the Builder pursuant to Article 3.2 and Article 3.5, and in connection therewith, its rights
                to, and interest in the Buyer’s Parent Company Guarantee and the Security Documents, to any party, financial institution or entity whatsoever with prior written consent of Buyer’s Parent Company, such consent not to be unreasonably
                withheld. The Buyer shall be entitled to comply with the terms of such notice without enquiry and payment in accordance with the notice shall be good discharge by the Buyer of its obligations and deemed for all purposes to be satisfaction
                by the Buyer of Its obligation to the Builder in respect of such assigned payments.

            

    

     

    
      	19.2	
              This Contract shall bind and inure for the benefit of the successors and assigns of the parties, but, save as stated in Clause 19.1 hereinabove, the rights of either party may not be assigned without the prior
                written consent of the other party.

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 34 of 51

      
        
 

    

    ARTICLE 20

      

      INVENTORIES ON THE RIG AT DELIVERY

     

    
      	20.1	
              An inventory of unused lubricating oil, grease, fuel oil or other liquids, supplied by Builder and left on board at delivery of the Rig shall be purchased and paid for by Buyer. Buyer will take over the remaining
                bunkers and unused lubricating oils in storage tanks and unbroached drums and pay the current market price for the quantities taken over. Payments therefore shall be made by Buyer to Builder immediately after receipt of invoice from
                Builder. Spares are not included in this sale. Items on board which are on hire or owned by third parties (if any) are excluded from the sale.

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 35 of 51

      
        
 

    

    ARTICLE 21

      

      BUILDER’S AND BUYER’S INDEMNITIES

     

    
      	21.1	
              Builder agrees to protect, indemnify and hold Buyer free and harmless from and against any and all claims or liabilities (including, without limitation, the cost of the suit and reasonable attorney’s fees) arising
                in favor of any of Builder’s (or its affiliates) employees, agents, officers, invitees, subcontractors (or their servants) or representatives, or any survivor of the foregoing on account of injury to or death of any such parties or damage
                to any of their property, including the Rig, attributable to the actions (or lack thereof) by any such parties in connection with the Rig and/or work performed pursuant to this Contract, regardless of whether Buyer and/or its subcontractors
                and/or others may be wholly, partially or solely negligent or otherwise at fault.

            

    

     

    
      	21.2	
              Buyer agrees to protect, indemnify and hold Builder and its subcontractors free and harmless from and against any and all claims or liabilities (including, without limitation, the cost of the suit and reasonable
                attorney’s fees) arising in favor of any of Buyer’s (or its affiliates) employees, agents, officers, invitees, subcontractors (or their servants) or representatives (including Buyer’s Representative), or any survivor of any of the foregoing
                on account of injury to or death of any such parties or damage to any of their property except as regards Rig attributable to the actions (or lack thereof) by any such parties in connection with the Rig and/or work performed pursuant to
                this Contract, regardless of whether Builder or its subcontractors and/or others may be wholly, partially or solely negligent or otherwise at fault.

            

    

     

    
      	21.3	
              Indemnities reasonably requested by OEMs as a precondition for the supply of its equipment or product, for liability which may arise in connection with export of the Rig from Singapore, shall be provided by Buyer.

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 36 of 51

      
        
 

    

    ARTICLE 22

      

      PATENT, TRADEMARKS , COPYRIGHTS

     

    
      	22.1	
              Builder warrants that ownership or operation of the Rig shall not at any time infringe any patent rights, utility model-rights,
                trade mark rights or copyrights in any country. Builder shall without limit of time defend any claim, suit or proceeding brought against Buyer relating to the infringement of any of the rights aforementioned by reason of Buyer’s possession,
                ownership or operation of the Rig and Builder shall indemnify and hold harmless Buyer from and against any such claim, suit or proceedings. Buyer shall promptly notify Builder of any such claim suit or proceeding and shall permit Builder to
                take control and settlement of such claim, suit or proceedings; provided however no settlement which purports to acknowledge on Buyer’s behalf the validity of any patent shall be entered into without the Buyer’s written consent. Buyer shall
                provide information and assistance to Builder as may be reasonably necessary to aid in the conduct and settlement of the claim, suit or proceedings. Buyer shall be entitled to participate in the settlement through its selected
                representatives and/or attorneys. Provided always that the indemnity provided herein by Builder shall not apply to equipment and materials furnished or supplied by OEM aforementioned in Article 12.5 and to Buyer’s supplies.

            

    

     

    
      	22.2	
              Buyer shall, without limitation of time, defend any claim, suit or proceeding brought against Builder, its parent, holding, or affiliated companies, alleging that the construction or use by Builder, pursuant to
                this Contract, of any design, process, device, apparatus specified or furnished by Buyer and mounted upon or used in connection with the Rig constitutes infringement of any patent, and Buyer shall indemnify, defend and save Builder, its
                parent, holding and affiliated companies, harmless from and against any such claim, suit or proceeding. Builder shall promptly notify Buyer of any such claim, suit or proceeding and shall permit Buyer to control the conduct and settlement
                of such claim, suit or proceeding; provided however, no settlement which purports to acknowledge on Builder’s behalf the validity of any patent shall be entered into without Builder’s prior written consent. Builder shall provide information
                and assistance to Buyer, at Builder’s expense, as may be reasonably necessary to aid in the conduct and settlement of the claim, suit or proceeding. Builder shall be entitled to participate, at its own expense, in the conduct and settlement
                of such claim, suit or proceeding through its selected representatives and attorneys.

            

    

     

    
      	22.3	
              Buyer acknowledges that Builder may disclose to Buyer confidential information and intellectual property relating to the Rig belonging to Builder, including the Rig’s design, construction, engineering and
                technical specifications, know-how, procedures, processes, drawings and plans, and Buyer agrees not to reproduce, reverse-engineer, decompile, or disassemble in any manner or form any such confidential information or Intellectual property,
                except with the prior written consent of or express license from Builder.

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 37 of 51

      
        
 

    

    ARTICLE 23

      

      USE OF CRANES

     

    
      	23.1	
              Builder has the right to use the Rig cranes forming a part of Builder’s furnished equipment, but only:

            

    

     

    
      	

            	(a)	
              for the purpose of construction of the Rig;

            

    

     

    
      	

            	(b)	
              in accordance with manufacturer’s instructions; and

            

    

     

    
      	

            	(c)	
              using duly qualified crane operators.

            

    

     

    Any repairs to such cranes made necessary by the use by Builder, shall be for the account of Builder and shall be carried out prior to the Delivery Date.

     

    
      	23.2	
              On delivery of the Rig:

            

    

     

    
      	

            	(a)	
              If the fast line wire rope in each crane has been used for more than six hundred (600) hours, Builder shall replace the fast line wire rope in that crane free of charge.

            

    

     

    
      	

            	(b)	
              If the main hook wire line in each crane has been used for more than six hundred (600) hours, Builder shall replace the main hook wire line in that crane free of charge.

            

    

     

    
      	23.3	
              Prior to delivery of the Rig, Builder shall ensure that the OEM has conducted a full inspection of the Rig cranes with Buyer, and any deficiencies will be rectified prior to delivery.

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 38 of 51

      
        
 

    

    ARTICLE 24

      

      EVENTS OF DEFAULT

     

    
      	24.1	
              The following shall constitute events of default of Builder under the Contract:

            

    

     

    
      	

            	(a)	
              Without prejudice to the condition for payment of the First Payment as set out In Article 3.2(a), if Builder fails to provide the Builder’s Parent Company Guarantee within 10 days of the date of this Agreement,
                the Buyer shall have the right to cancel this Agreement in its sole discretion on notice to Builder, such cancellation notice having immediate effectiveness and neither Party shall have any further
                obligation to the other Party

            

    

     

    
      	

            	(b)	
              Builder or Builder’s Guarantor voluntarily or involuntarily being made a part to any receivership, liquidation, or bankruptcy proceeding (which proceedings are not stayed
                within thirty (30) days of the service of such proceedings on Builder or Builder’s Guarantor) or becoming insolvent or in the event Builder or Builder’s Guarantor is unable to meet all or part of its financial or other obligations under
                this Contract or the Builder’s Guarantor (as the case may be) or is unable to or does not pay its debts as they fall due, unless as a sole and direct result of Buyer’s failure to make payments as due under this Contract.

            

    

     

    
      	

            	(c)	
              If (i) the total accumulated non-permissible delays (Including the grace period but excluding Permissible Delays as allowed under the terms of this Contract) and (ii) any delays permitted pursuant to Article 6.9
                exceeds in aggregate two hundred and forty (240) days.

            

    

     

    
      	

            	(d)	
              The Builder’s Parent Company Guarantee ceases to be in full force and effect.

            

    

     

    
      	24.2	
              The following shall constitute events of default of Buyer under this Contract:

            

    

     

    
      	

            	(a)	
              Should the First Payment not be paid in accordance with Article 3.2(a), Builder shall have the right to cancel this Agreement in its sole discretion on notice to Buyer, such cancellation notice having immediate
                effectiveness, and neither Party shall have any further obligation to the other Party except for obligations under this Agreement that survive termination.

            

    

     

    
      	

            	(b)	
              if after the Delivery Date, the Buyer fails to pay the Balance Payment as stated in Article 3.2(b), or fails to pay the quarterly interest on the Balance Payment as stated in Article 3.2(b)(i) to Article
                3.2(b)(iii), or fails to pay the Back End Fee as stated in Article 3.5, or, if the Buyer fails to make payment of any Variation, or If after the Contract Delivery Date the Buyer or Buyer Parent Company is voluntarily or Involuntarily made a
                part of any receivership, liquidation or bankruptcy proceedings, or Buyer or Buyer Parent Company becomes insolvent or otherwise unable to meet or all or part of its financial or other obligations under this Contract or If an event of
                default occurs under the terms of any of the Security Documents; or

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 39 of 51

      
        
 

    

    
      	

            	(c)	
              If, in the reasonable opinion of the Builder, any of the securities granted to the Builder under the terms of the Security Documents are in jeopardy and notice thereof has been given to the Buyer; or

            

    

     

    
      	

            	(d)	
              If after the Delivery Date, anything is done or omitted to be done by the Buyer’s Parent Company which in the reasonable opinion of the Seller, materially impairs or renders insufficient or inadequate the Buyer’s
                Parent Company Guarantee; or

            

    

     

    
      	

            	(e)	
              If after the Delivery Date, there should occur any event or change or series of events which in the reasonable opinion of Builder, would have a material or adverse effect on the business or financial condition of
                the Buyer or the Buyer’s Parent Company or a material or adverse effect on the ability of the Buyer’s Parent Company to perform Its obligations under the Buyer’s Parent Company Guarantee; or

            

    

     

    
      	

            	(f)	
              If after the Delivery Date, any indebtedness of an amount more than [***]% of the Buyer’s Parent Company’s tangible net worth, is not paid when due, or is or is declared to be or is capable of being declared due
                and payable before its normal maturity,

            

    

     

    the Builder shall have the remedies as specified in the Security Documents. In this regard, in the event there is a shortfall in the proceeds of any
      judicial or mortgagee’s sale of the Rig and the First Payment retained by the Builder, the Builder shall have the right to claim the balance of the indebtedness due to It pursuant to this Contract from the Buyer. Further, in the event the Builder
      realises a surplus from any mortgagee’s sale of the Rig, the Builder shall be entitled to retain such surplus. For the purpose of clarification and avoidance of doubt, In such event, Builder shall also have the right to appropriate and forfeit the
      First Payment and any interest already paid by Buyer pursuant to Article 3.2 (b) (i)-(iii) and any payment for Variation Orders, and the Parties acknowledge that the appropriation and forfeiture of the First Payment and any interest already paid by
      Buyer pursuant to Article 3.2 (b) (i)-(iii) and any payment for Variation Orders by Builder is a reasonable and agreed pre-estimate of the Builder’s loss and not a penalty, and that this is a reasonable allocation of risks between the Parties and
      that the Purchase Price is established on these terms.

     

    
      	

            	(g)	
              in the event Buyer fails to take Delivery and Acceptance of the Rig as per Article 6 (Delivery); or

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 40 of 51

      
        
 

    

    
      	

            	(h)	
              If prior to the Contract Delivery Date, the Buyer or the Buyer’s Parent Company Is voluntarily or involuntarily made a part of any receivership, liquidation or bankruptcy proceedings which proceedings are not
                stayed within thirty (30) days of the service of such proceedings on Buyer or Buyer’s Parent Company r) [sic] or the Buyer or the Buyer’s Parent Company becomes insolvent or otherwise unable
                to meet all or part of its financial or other obligations under this Contract, the Builder shall have the right to terminate this Contract and appropriate the First Payment; or

            

    

     

    
      	

            	(i)	
              In the event the Buyer fails to comply with its obligations under Article 2.2 and fails to rectify such non-compliance within 14 days of the Builder’s written notice to the Buyer to do so; or

            

    

     

    
      	

            	(j)	
              If prior to the Delivery Date, there should occur any event or change or series of events which in the reasonable opinion of Builder, would have a material or adverse effect on the business or financial condition
                of the Buyer or the Buyer’s Parent Company or a material or adverse effect on the ability of the Buyer’s Parent Company to perform its obligations under the Buyer’s Parent Company Guarantee; or

            

    

     

    
      	

            	(k)	
              If prior to the Delivery Date, any indebtedness of an amount more than [***]% of the Buyer’s Parent Company’s tangible net worth, is not paid when due, or is or is declared to be or is capable of being declared
                due and payable before its normal maturity,

            

    

     

    Builder may at its option by notice In writing (“Termination Notice”) terminate this Contract. Upon receipt by Buyer of the Termination Notice, the
      Contract shall forthwith become terminated, and in that event, (or any other termination of the Contract by reason of Buyer’s breach), notwithstanding any provision in this Contract herein, property in the Rig and all the materials and equipment
      forming part of the Rig or intended to be incorporated into it shall in accordance with Article 5.1 herein remain with Builder. Further, in such event, title in any OFE which are already installed or incorporated In the Rig shall remain with Builder.
      Further, it is understood that Builder shall be entitled to appropriate and forfeit all payments made under the Contract by Buyer to Builder before termination since the Contract is not a simple contract of sale of goods and there will have been no
      total failure of consideration for those payments. Any OFE which has not been installed or incorporated in the Rig shall be returned by Builder to Buyer. The Parties acknowledge that the appropriation and forfeiture of the First Payment and any
      payment for Variation Orders by the Builder is a reasonable and agreed pre-estimate of the Builder’s loss and not a penalty, and that this Is a reasonable allocation of risks between the Parties and that the Purchase Price is established on these
      terms.

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 41 of 51

      
        
 

    

    
      	24.3	
              In the event of default by Builder, Buyer may at its option within fourteen (14) days from the date thereof, elect to proceed on either one of the following options:

            

    

     

    
      	

            	(a)	
              terminate this Contract in the manner set out in Article 24.4; or

            

    

     

    
      	

            	(b)	
              without prejudice to Buyer’s right to recover liquidated damages for delay pursuant to Article 8 (Damages for Delays), allow Builder to continue to complete the construction of the Rig In the manner set out in
                Article 24.5.

            

    

     

    Buyer shall inform Builder in writing of its intention to elect (a) or (b) above, and shall be deemed to have waived its right to terminate this Contract
      if it fails to do so within fourteen (14) days of the event of default.

     

    
      	24.4	
              In the event that Buyer elects to terminate the Contract pursuant to Article 24.3(a) due to an event of default by Builder:

            

    

     

    
      	

            	(a)	
              Buyer shall notify Builder in writing of its intention to do so and such termination shall be effective as of the date when such notice is received by Builder.

            

    

     

    
      	

            	(b)	
              Builder shall immediately refund to Buyer the First Payment plus Interest at the rate of [***]% above the Average LIBOR calculated from the date of payment to the date of refund and any other amounts paid under
                this Contract by Buyer for Variations or otherwise. Builder shall also return Buyer’s OFE, or if they cannot be returned, Builder shall pay to Buyer an amount equal to Buyer’s costs for such equipment

            

    

     

    
      	

            	(c)	
              Buyer shall not in the event of the termination of this Contract hereunder be entitled to any liquidated damages under Article 8 (Damages for Delays).

            

    

     

    
      	

            	(d)	
              Upon such refund by Builder to Buyer as aforementioned, all obligations, duties and liabilities of each of the parties to the other under this Contract shall be forthwith completely discharged, and Buyer shall
                have no further claim on Builder.

            

    

     

    
      	24.5	
              In the event Buyer elects pursuant to Article 24.3(b) to allow Builder to continue to complete the construction of the Rig, Builder shall pay Buyer the liquidated damages due pursuant to Article 8 (Damages for
                Delays), and Builder shall work with Buyer to produce an acceptable schedule for the completion of the remaining work on the Rig and work diligently to complete the construction of the Rig.

            

    

     

    
      	24.6	
              The Builder irrevocably agrees that if, following a demand by the Buyer for repayment under this Article 24, Builder or Builder’s Guarantor does not make immediate refund to Buyer, Buyer shall be entitled to serve
                notice exercising its right to pay the Balance Payment and the Back End Fee and take delivery of the Rig under this Agreement.

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 42 of 51

      
        
 

    

    
      	24.7	
              In relation to termination of the Contract under any of Articles 24.2 or 24.4, or repudiatory or other breach of contract or any other reason whatsoever, and whether or not under a term of the Contract, the
                following shall apply, and notwithstanding any other term of the Contract:

            

    

     

    
      	

            	(a)	
              Builder/Buyer each expressly acknowledges that its sole and only remedy under the Contract shall be those provided for in this Contract, namely those set out in Articles 24.2 and, 24.4 (“Termination Remedies”);

            

    

     

    
      	

            	(b)	
              Builder and Buyer each expressly waives Its rights to claim damages at large or any other remedy under this Contract or under the general law for or arising out of termination of this Contract. Builder and Buyer
                hereby expressly acknowledge the adequacy of the remedy provided by the Termination Remedies.

            

    

     

    
      	

            	(c)	
              It is further agreed by Buyer that the refund due from Builder pursuant to the Termination Remedies shall constitute an adequate and entire remedy for any loss whatsoever suffered by Buyer, and accordingly, Buyer
                expressly waives any rights it may have to seek specific performance of the Contract (whether or not the Contract has actually been terminated).

            

    

     

    
      	

            	(d)	
              On such termination, the uncompleted Rig, including all OFE installed or incorporated in the Rig, and ail work in progress shall immediately be at the free disposal of Builder, provided that Builder has made any
                refund due to Buyer and paid for any OFE as may be required by this Contract.

            

    

     

    Buyer also agrees that it shall not challenge or interfere in any way with the ownership of and free disposal of the Rig, including any OFE installed in
      or incorporated in the Rig, whether in its completed or uncompleted state, and all work in progress, by Builder (and its successors in title).

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 43 of 51

      
        
 

    

    ARTICLE 25

      

      COMPLIANCE WITH LAWS

     

    
      	25.1	
              Each of Buyer and Builder warrants and undertakes to the other that:

            

    

     

    
      	

            	(a)	
              while acting in connection with this Contract, it will not violate or assist or instigate any other individual or legal entity to violate, any applicable law, including without limitation the United Kingdom
                Bribery Act 2010 and the United States Foreign Corrupt Practices Act or any other applicable anti-bribery laws or anti-terrorism laws or money laundering laws;

            

    

     

    
      	

            	(b)	
              all of their respective officers, employees, consultants, representatives, agents, business partners, joint-ventures and affiliates who are engaged in implementing this Contract shall:

            

    

     

    
      	

            	(i)	
              be knowledgeable regarding the purpose and provisions of all applicable anti-corruption and anti-bribery laws;

            

    

     

    
      	

            	(ii)	
              comply with applicable anti-bribery and anti-corruption laws; and

            

    

     

    
      	

            	(iii)	
              not take, or will refrain from taking, any action which would cause either Buyer or Builder to be in violation of the terms of applicable anti-bribery and anti-corruption laws.

            

    

     

    
      	25.2	
              Buyer warrants and undertakes to Builder that:

            

    

     

    
      	

            	(a)	
              the execution, delivery, and performance of the transaction contemplated under this Contract shall be in compliance with all applicable laws including, without limitation, all applicable .Export and Import Laws
                (as defined below).

            

    

     

    
      	

            	(b)	
              Buyer is unconditionally responsible for complying with such laws;

            

    

     

    
      	

            	(c)	
              neither Buyer nor any of its affiliates, or successor in interest, nor any client/operator or its affiliates, is or will be a person, company, or entity:

            

    

     

    
      	

            	(i)	
              with whom Builder is prohibited from dealing or otherwise engaging in any transaction by any law related to the proliferation of nuclear, missile, or chemical/biological weapons, or missiles that deliver such weapons;

            

    

     

    
      	

            	(ii)	
              with whom Builder is prohibited from dealing or otherwise engaging in any transaction by any law related to transactions involving countries against which any government of the United Kingdom (“UK”) or the United States of America
                (“US”), the Organisation for Economic Cooperation and Development (“OECD”), the European Union or other international organization maintains economic sanctions or embargoes under statute, executive order or regulations;

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 44 of 51

      
        
 

    

    
      	

            	(iii)	
              appearing on any applicable list of prohibited parties maintained by any of the governments referred to above; or

            

    

     

    
      	

            	(iv)	
              acting or purporting to act, directly or indirectly, on behalf of, or an entity owned or controlled by, any party identified in Article 25.2(c) above.

            

    

     

    
      	

            	(d)	
              it shall not export the Rig and/or any related equipment (including, without limitation, any accompanying technology, software or other technical data) directly or indirectly without the necessary authorizations,
                licenses, permits or approvals from the UK, US or other relevant government authority as required by the relevant Export and Import Laws except that, in the case of any such applicable trade restrictions outside the UK and US laws, only to
                the extent consistent with such UK or US laws.

            

    

     

    All laws and regulations that govern the restrictions and prohibitions referenced in Article 25.2(c) and Article 25.2(d) shall be referred to as Export
      and Import Laws.

     

    
      	25.3	
              Builder shall abide by and comply with all valid laws and regulations of Singapore. Builder will avoid or refrain from doing anything under this Contract which may be an actual or possible breach of any sanctions,
                prohibition or requirement imposed by the laws, regulations, resolutions, or administrative orders of the United States of America, United Nations, European Union or any other jurisdiction applicable to any of Builder’s obligations under
                this Contract. Where Builder is so prevented from performing any work or obligation under this Contract, Builder shall have no liability to Buyer for Its inability to perform this work or obligation and Builder shall be entitled to deliver
                the Rig to Buyer without the relevant work or obligation being performed, subject to an appropriate price adjustment. In the case where such prevention occurs after delivery of the Rig, Seller shall be entitled to avoid performing the
                affected post-delivery work or obligation, if any.

            

    

     

    
      	25.4	
              Should any governmental law, regulation, ruling and/or policy (including but not limited to import/export restrictions, exchange controls or requirements) effectively prohibit or restrict Builder from receiving
                payment under this Contract, then Builder shall promptly notify Buyer of any such restriction or prohibition and the Parties shall discuss to find a mutually acceptable solution.

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 45 of 51

      
        
 

    

    
      	25.5	
              Where Builder is prevented from performing its obligations under this Contract by any actions or causes attributable to Buyer, and such prevention continues for more than fourteen (14) days without being resolved,
                then this Contract may at Builder’s option be terminated. In the event of such termination, the provisions of Article 24 shall apply.

            

    

     

    
      	25.6	
              Builder shall comply with all provisions of the Specifications relating to health, safety and environmental matters and shall provide the Buyer with its Health, Safety & Environmental Protection plan (the “HSE
                Plan”) within 30 days of the Effective Date.

            

    

     

    
      	25.7	
              Without prejudice to the Buyer’s other rights and remedies under the Contract and without the Buyer assuming any responsibility or liability for any obligation to inspect and discover or to require Builder to
                cease unsafe practices and without diminishing Builder’s sole responsibility to ensure that Work is conducted safely, if the Buyer detects any unsafe procedures or work or any procedures or work which violates any applicable laws, rules or
                regulations or the HSE Plan, Buyer shall inform Builder and the Parties shall mutually discuss for Builder to remedy any alleged shortcomings in Builder’s HSE practice.

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 46 of 51

      
        
 

    

    ARTICLE 26

      

      LIMITATION ON LIABILITY

     

    
      	26.1	
              Notwithstanding anything to the contrary set forth herein in this Contract but except where due to willful misconduct on the part of the Builder’s senior management or the Buyer’s senior management, neither
                Builder nor Buyer shall be liable to the other for any of the following (whether direct, indirect or consequential): loss of use of the Rig, loss of data, loss of time, loss of production, loss of business, loss of contracts, loss of
                charter hire, loss of opportunity, loss of goodwill or reputation, loss of profits or earnings or anticipated revenue, financing costs, losses or claims resulting from failure to meet any contractual commitments or deadlines and downtime of
                facilities or equipment or any other property, or for any financial or economic loss, or for any incidental, indirect, consequential, exemplary, special or punitive losses or damages of any kind whatsoever, howsoever the same may have been
                caused or arisen whether by way of indemnity or by reason of any breach of warranty, breach of contract, negligence, tort, strict liability, statutory duty or by reason of anything under common law, equity or otherwise.

            

    

     

    
      	26.2	
              Except for Builder’s obligations pursuant to Clause 21.1 (Indemnity), Builder’s maximum liability to Buyer arising out of or in connection with the Contract for any loss or damage including but not limited to:
                liquidated damages for delay, costs, claims or expenses, howsoever they may have been caused or arisen, whether arising under common law, contract, negligence, tort, equity, strict liability, statute or otherwise shall be limited in the
                aggregate to [***] percent ([***]%) of the Purchase Price. Buyer agrees to release Builder, its officers and servants, from and against any liability in excess thereof. Builder and Buyer agree that this provision is a reasonable allocation
                of risks between the Parties and that the Purchase Price is established on these terms.

            

    

     

    
      	26.3	
              For pollution related issues after delivery of the Rig, Buyer shall indemnify and hold Builder harmless, provided however that in the event where within twelve (12) months after the delivery of the Rig, if such
                pollution issues are caused by Builder’s negligence in the design or construction of the Rig, Builder shall indemnify and hold Buyer harmless for an amount up to United States Dollars One Million (US$1,000,000) only. Builder and Buyer agree
                that this provision is a reasonable allocation of risks between the Parties and that the Purchase Price is established on these terms

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 47 of 51

      
        
 

    

    ARTICLE 27

      

      MISCELLANEOUS

     

    
      	27.1	
              Throughout the term of this Contract, Builder shall be an independent contractor in relation to Buyer

            

    

     

    
      	27.2	
              The intellectual property rights relating to designs, drawings, Specifications, instructions, manuals, computer programs and other documents created or produced by Builder or Its subsidiaries which are proprietary
                to Builder, shall be and remain the property of Builder.

            

    

     

    
      	27.3	
              This Contract and all information exchange between Builder and Buyer, including all prices and any information such as documents, design, drawings, Specifications, instructions, manuals, computer programs relating
                to the design and construction of the Rig which are provided by Builder to Buyer or which may otherwise be acquired by Buyer, regardless of whether they are Builder’s proprietary information, shall not be disclosed to any third party
                without the prior authorization of Builder. Buyer shall be responsible for keeping confidential all such information, and shall not permit any such information to be shown, reproduced or otherwise disclosed to any third party by itself, its
                subcontractors or their respective personnel. Neither party shall make announcements or media release without the consent of the other.

            

    

     

    
      	27.4	
              Where a provision in this Contract for any reason becomes unenforceable or invalid, the remainder of the Contract shall remain in full force and effect. Where severance of a non-enforceable provision in the
                opinion of either party materially affects the other rights or obligations under the Contract, the parties shall endeavor to remedy the situation to their mutual satisfaction.

            

    

     

    
      	27.5	
              The parties have entered into this Contract freely, willingly, and on equal commercial basis, having had the opportunity to fully consider the contents of the Contract. It is hereby agreed that no terms or
                conditions herein shall be construed against a party simply by reason that the party had proffered a particular term or condition.

            

    

     

    
      	27.6	
              Save as set forth in this Contract, a person who is not a party to this Contract has no right whatsoever to enforce any term of this Contract. For the avoidance of doubt, the parties agree that the application of
                any statutes which may confer rights on third parties is expressly excluded.

            

    

     

    
      	27.7	
              This Contract contains the entire contract and understanding between the parties hereto and supersedes all prior negotiations, representations, understandings and agreements on any subject matter of this Contract.

            

    

     

    27.8

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 48 of 51

      
        
 

    

    ARTICLE 28

      

      EFFECTIVE DATE OF CONTRACT

     

    
      	28.1	
              This Contract shall become immediately effective and legally binding on the parties on the satisfaction of the conditions set out in the Master Agreement (defined therein as the “Effective Date”) and delivery of
                the Builder’s Parent Company Guarantee to Buyer.

            

    

     

    
      	28.2	
              The date when the above condition is satisfied shall be known hereunder as the “Effective Date”

            

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 49 of 51

      
        
 

    

    ARTICLE 29

      

      NOTICES

     

    
      	29.1	
              All notices and communications required to be given hereunder shall be in the English language and be served by delivering the same by courier or in person to such other party, by email or by facsimile with a
                transmission report evidencing the successful transmission of the same.

            

    

     

    
      	29.2	
              Such notices and communications shall be addressed to the respective party’s authorized representative {as described in Article 9 (Buyer’s Representative and Builder’s Representative)}.

            

    

     

    
      	29.3	
              Notice so given shall be effective if and when (as the case may be) it arrives by courier at the specified address or is delivered in person at the specified address or is successfully transmitted (as evidenced by
                a transmission report) by email or facsimile to the specified facsimile number, regardless of the time when it is first personally received or seen by, or otherwise comes to the attention of, the relevant party, or Its authorized
                representatives.

            

    

     

    
      	29.4	
              Any and all notices and communications in connection with the Contract shall be addressed as follows:

            

    

     

    BUYER

      c/o BORR JACK-UP [ ] INC

      c/o Quorum Services Limited, Thistle House, 4 Burnaby Street,

      Hamilton HM 11, Bermuda

      Email:[***]

     

    Attention:                   [***] __________ (Buyer’s Representative)

     

    BUILDER

      PPL SHIPYARD PTE LTD

      21 Pandan Road

      Singapore 609273

      Telephone No:          [***]

      Telefax No:                [***]

      Email:

     

    Attention:                 [***]_________________ (Builder’s
        Representative)

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

    
      Page 50 of 51

      
        
 

    

    IN WITNESS WHEREOF, the parties hereto have executed this Contract in multiple originals effective as of the day and year first
      above written.

     

    
      	
              For and on behalf of Buyer

                BORR JACK-UP [     ] INC

            	 	
              For and on behalf of Builder

                PPL SHIPYARD PTE LTD

            
	 	 	 
	 

            	 	
              [***]

              MANAGING DIRECTOR

            

      

      

      	
              WITNESS :

            	 	 	
              WITNESS :

            	 

      

      

      	
              Date:

            	 	 	
              Date:

            	 

    

     

    Pacific Class® 400 Rig Construction Contract (PPl Hull No. P2047) 

     

    Page 51 of 51Exhibit 10.4

   

  EXHIBIT A

   

  Execution Version

   

  TENDER OFFER AGREEMENT

   

  by and between

   

  BORR DRILLING LIMITED

   

  and

   

  PARAGON OFFSHORE LIMITED

   

  dated as of

   

  February 21, 2018

  
    
      
 

  

  
  TABLE OF CONTENTS 

   

  	 	

        	Page
	ARTICLE I THE OFFER	1
	 	 
	Section 1.1	The Offer	1
	Section 1.2	Company Actions	6
	 	 	 
	ARTICLE II REPRESENTATIONS AND WARRANTIES OF THE COMPANY 	6
	 	 
	Section 2.1	Qualification; Organization; Subsidiaries; and Company Board of Directors	7
	Section 2.2	Capitalization	7
	Section 2.3	Company Authority	8
	Section 2.4	Governmental Consents; No Violation	9
	Section 2.5	Litigation 	9
	Section 2.6	Specific Disclosures	9
	Section 2.7	Liens 	9
	Section 2.8	Finders and Brokers	10
	Section 2.9	No Other Representations	10
	 	 	 
	ARTICLE III REPRESENTATIONS AND WARRANTIES OF PURCHASER 	10
	 	 
	Section 3.1	Qualification, Organization, etc.	10
	Section 3.2	Purchaser Authority	10
	Section 3.3	Governmental Consents; No Violation	10
	Section 3.4	Availability of Financing	11
	Section 3.5	Disclosed Information	11
	Section 3.6	Finders and Brokers	11
	Section 3.7	No Other Representations	11
	 	 	 
	ARTICLE IV COVENANTS RELATING TO CONDUCT OF BUSINESS PENDING THE OFFER	12
	 	 
	Section 4.1	Conduct of Business by the Parties Pending the Acceptance Time	12
	Section 4.2	Superior Proposal	14
	 	 	 
	ARTICLE V ADDITIONAL AGREEMENTS	14
	 	 
	Section 5.1	Notice of Certain Events	14
	Section 5.2	Reasonable Best Efforts and Cooperation	15
	Section 5.3	Publicity	16
	Section 5.4	Directors’ and Officers’ Insurance and Indemnification	16
	Section 5.5	Employee Benefits Matters	18
	Section 5.6	Employment Matters	18
	Section 5.7	Payments at the Acceptance Time	18
	Section 5.8	Security Holder Litigation	18
	Section 5.9	Prospector Rigs	18

  
    i

    
      
 

  

  	
          Section 5.10

        	Shareholders’ Agreement	19
	 	 	 
	ARTICLE VI TERMINATION	19
	 	 
	
          Section 6.1

        	Termination	19
	
          Section 6.2

        	Effect of Termination	20
	 	 	 
	ARTICLE VII MISCELLANEOUS 	21
	 	 
	
          Section 7.1

        	Amendment and Modification; Waiver	21
	
          Section 7.2

        	Non-Survival of Representations and Warranties	21
	
          Section 7.3

        	Expenses	21
	
          Section 7.4

        	Notices	21
	
          Section 7.5

        	Interpretation	22
	
          Section 7.6

        	Counterparts	23
	
          Section 7.7

        	Entire Agreement; Third-Party Beneficiaries	23
	
          Section 7.8

        	Severability	23
	
          Section 7.9

        	Governing Law; Jurisdiction	23
	
          Section 7.10

        	Waiver of Jury Trial	24
	
          Section 7.11

        	Assignment	24
	
          Section 7.12

        	Enforcement; Remedies	25

   

  	Annex A	Certain Definitions	 
	 	 	 
	Annex B	List of Tendering Members	 
	 	 	 
	Annex C	Form of Offer to Purchase	 
	 	 	 
	Annex D	Rig Delivery Protocol	 
	 	 	 
	Annex E	Closing Payments	 

  
    ii

    
      
 

  

  
  TENDER OFFER AGREEMENT 

  

  

  This TENDER OFFER AGREEMENT (this “Agreement”), dated as of February 21, 2018, is by and between Borr Drilling Limited, a
    public limited company incorporated under the laws of Bermuda (“Purchaser”), and Paragon Offshore Limited, an exempted company limited by shares incorporated under the laws of the Cayman Islands (the “Company”). All capitalized terms used
    in this Agreement shall have the meanings ascribed to such terms in Annex A or as otherwise defined elsewhere in this Agreement unless the context clearly provides otherwise. Purchaser and the Company are each sometimes referred to herein as a
    “Party” and collectively as the “Parties”.

   

  RECITALS

   

  WHEREAS, it is proposed that Purchaser shall commence a tender offer (the “Offer”) to acquire all of the outstanding shares,
    par value $0.001 per share (or beneficial interests therein), of the Company (the “Company Shares”) for the consideration and upon the terms and subject to the conditions set forth herein;

   

  WHEREAS, the board of directors of the Company (the “Company Board of Directors”) (a) approved the execution and delivery by
    the Company of, and the performance by the Company of its obligations under, this Agreement, (b) determined that the Offer is in the best interests of the Company and recommended that the holders of Company Shares accept the Offer and tender their
    Company Shares to Purchaser pursuant to the Offer and (c) approved the acquisition by Purchaser of the Company Shares pursuant to the Offer for purposes of Section 49(a) of the Company Articles and Section 4.02(a) of the Shareholders’ Agreement (the “Company

      Board Recommendation”);

   

  WHEREAS, as an inducement to and condition of Purchaser’s willingness to enter into this Agreement, prior to the entry of the Parties
    into this Agreement, each of the Company’s members set forth on Annex B (collectively, the “Tendering Members”), which Tendering Members collectively beneficially own 3,407,072 Company Shares representing approximately 67.90% of the
    outstanding Company Shares as of the date hereof, entered into individual Tender Support Agreements with Purchaser, pursuant to which, among other things, the Tendering Members have agreed to tender all Company Shares beneficially owned by such
    Tendering Members into the Offer; and

   

  NOW, THEREFORE, in consideration of the mutual covenants and agreements contained in this Agreement and for other good and valuable
    consideration, the receipt and adequacy of which are hereby acknowledged, the Parties agree as follows:

   

  ARTICLE I

   

  THE OFFER

   

  Section 1.1          The Offer.

   

  (a)           Terms and Conditions of the Offer.

   

  (i)         Provided that this Agreement shall not have been terminated pursuant to Article VI, as
    promptly as practicable after the date hereof (but in no event more than five (5) Business Days after the date hereof), Purchaser shall commence the Offer to purchase any and all of the outstanding Company Shares.

  
    1

    
      
 

  

  (ii)         In the Offer, each Company Share accepted by Purchaser in accordance with the terms and
    subject to the conditions of the Offer and in compliance with applicable Law shall be exchanged for the right to receive, in each case subject to the other provisions of this Article I and subject to reduction for any applicable withholding
    taxes in respect thereof, without interest (collectively, the “Tender Offer Consideration”):

   

  (1)        cash in an amount equal to US $42.28 per Company Share; plus

   

  (2)        the right to receive from Purchaser cash in an amount equal to the Per Share Jindal Payable
    Amount, if any.

   

  (iii)        The Offer shall be made by means of an Offer to Purchase, substantially in the form attached
    hereto as Annex C (the “Offer to Purchase”), that is disseminated to all of the holders of Company Shares. Purchaser shall use its reasonable best efforts to consummate the Offer, subject to the terms and conditions hereof and thereof.

   

  (iv)        Purchaser’s rights and obligations to accept for payment or pay for any Company Shares that
    are validly tendered in the Offer and not withdrawn shall be subject only to the following conditions having been satisfied or waived by the Purchaser (collectively, the “Offer Conditions”):

   

  (1)        the condition that, prior to the expiration of the Offer, there be validly tendered and not
    withdrawn in accordance with the terms of the Offer a number of Company Shares that, together with the Company Shares then owned by Purchaser (if any), equals at least 3,361,763 Company Shares, representing at least 67% of all then outstanding Company
    Shares;

   

  (2)       the condition that any pre-closing approvals or clearances reasonably required under any
    applicable Antitrust Laws shall have been obtained and any applicable waiting periods under any applicable Antitrust Laws shall have expired or been terminated;

   

  (3)        the condition that no Governmental Entity of competent jurisdiction shall have (A) enacted, issued or promulgated
    any Law that is in effect as of immediately prior to the expiration of the Offer, or (B) issued or granted any order or injunction that is in effect as of immediately prior to the expiration of the Offer, that, in each case, has the effect of
    restraining, enjoining or otherwise prohibiting the consummation of the Offer;

   

  (4)        the condition that the representations or warranties of the Company set forth in Article II shall be true
    and correct in all material respects as of the date of this Agreement and immediately prior to the Acceptance Time, except, in each case, to the extent a representation or warranty is made as of a specific date, then as of such date;

  
    2

    
      
 

  

  (5)        the condition that the Company shall have performed and complied in all material respects with
    its obligations under this Agreement that, by their terms, are to be performed or complied with by the Company prior to the Acceptance Time;

   

  (6)        the condition that no Company Material Adverse Effect shall have occurred after the date of this
    Agreement and prior to the Acceptance Time;

   

  (7)        the condition that the Company shall have completed all of the actions contemplated by the
    Prospector Rig Acquisition in accordance with Section 5.9 (it being agreed that the reference to the use of reasonable best efforts in such section does not apply to determine compliance with this condition);

   

  (8)       the condition that the rig delivery protocol set forth in Annex D shall have been
    completed with respect to each of the Prospector Rigs and delivered to Purchaser immediately prior to the Acceptance Time and, as a result thereof, there shall have been no (A) adverse findings in respect thereof or (B) reporting requirement of the
    type described in paragraph (4) of Annex D in respect of any incident in respect of either Prospector Rig; and

   

  (9)        the condition that this Agreement shall not have been terminated in accordance with Section
      6.1.

   

  (v)         In the event this Agreement is terminated pursuant to Section 6.1 prior to the
    Acceptance Time, Purchaser shall promptly terminate the Offer without accepting any Company Shares previously tendered and shall promptly return, and shall cause the transfer agent (or any other applicable agent) to promptly return, all tendered share
    certificates representing Company Shares to the holders thereof.

   

  (b)          Waivers and Amendments. Purchaser expressly reserves the right to waive any of the conditions to the Offer,
    subject to applicable Laws; provided, however, that notwithstanding the foregoing or anything to the contrary set forth herein, without the prior written consent of the Company, Purchaser may not (i) waive any
    of the Offer Conditions other than the Offer Conditions set forth in Section 1.1(a)(iv)(4) through Section 1.1(a)(iv)(8), and (ii) make any change in the terms of
    or conditions to the Offer that (1) changes the form of consideration to be paid in the Offer, (2) increases or decreases the consideration in the Offer or the number of Company Shares sought in the Offer, (3) extends the Offer, other than in a manner
    required by the provisions of Section 1.1(d), (4) imposes conditions to the Offer other than the Offer Conditions, (5) modifies the Offer Conditions, (6) increases or decreases any dealer soliciting fee to be given in connection with the Offer,
    or (7) amends any other term or condition of the Offer in any manner that is adverse to the holders of Company Shares.

   

  (c)          Adjustments to the Offer. The Tender Offer Consideration shall be adjusted appropriately to reflect the
    effect of any share division or consolidation, stock dividend, reorganization, recapitalization, reclassification, combination, exchange of shares or other like change with respect to the number of Company Shares, as applicable, outstanding after the
    date hereof and prior to Purchaser’s acceptance for payment of, and payment for, Company Shares that are tendered pursuant to the Offer.

  
    3

    
      
 

  

  (d)           Expiration and Extension of the Offer.

   

  (i)          Unless the Offer is extended pursuant to and in accordance with this Agreement, the Offer
    shall expire at 12:01 AM, Eastern Time, on the day immediately following the date that is twenty (20) business days (for this purpose calculated to be the later of (1) such date as is required to comply with Rule 14e-1(a) promulgated under the Exchange
    Act and (2) such date as is required to comply with Section 4.03 of the Shareholders’ Agreement) from the date the Offer is first commenced. In the event that the Offer is extended pursuant to and in accordance with this Agreement, then the Offer shall
    expire on the date and at the time to which the Offer has been so extended.

   

  (ii)         Notwithstanding the provisions of Section 1.1(d)(i) or anything to the contrary set
    forth in this Agreement, without the consent of the Company:

   

  (1)        Purchaser shall extend the Offer for any period required by any Law, any rule, regulation,
    interpretation or position of any applicable Governmental Entity overseeing the enforcement of Laws relating to tender offers, including the U.S. Securities and Exchange Commission, or Section 4.03 of the Shareholders’ Agreement; and

   

  (2)        without prejudice to its rights under Section 6.1 in the event that any of the Offer
    Conditions have not been satisfied or waived as of any then scheduled expiration of the Offer (other than those which are only capable of being satisfied as of the Acceptance Time), Purchaser shall extend the Offer for successive extension periods of
    up to ten (10) Business Days each in order to further seek to satisfy the Offer Conditions; 

   

  provided, however, that any such extension shall not be deemed to impair, limit, or otherwise restrict
    in any manner the right of the Parties to terminate this Agreement pursuant to the terms of Article VI; and, provided further, that Purchaser shall comply with any and all applicable securities Laws,
    including providing any and all notices required to be given in connection with any such extension.

   

  (iii)        Purchaser shall not terminate or withdraw the Offer prior to the then scheduled expiration of
    the Offer unless this Agreement is validly terminated in accordance with Article VI, in which case Purchaser shall irrevocably and unconditionally terminate the Offer promptly (but in no event more than two (2) Business Days) after such
    termination of this Agreement.

   

  (iv)         Nothing in this Section 1.1(d) shall be deemed to impair, limit or otherwise restrict
    in any manner the right of the Parties to terminate this Agreement pursuant to the terms of Article VI.

   

  (e)           Payment for Company Shares. On the terms and subject to conditions set forth in this Agreement and the
    Offer, Purchaser shall accept for payment and pay for, all Company Shares that are validly tendered and not withdrawn in the Offer promptly (within the meaning of Rule 14e-1(c) promulgated under the Exchange Act) after the expiration of the Offer (as
    it may be extended in accordance with Section 1.1(d)(ii)) (such time, the “Acceptance Time”). The cash consideration payable in respect of each Company Share validly tendered and not withdrawn in the Offer
    shall be paid to the holder thereof in cash, subject to reduction for any applicable withholding taxes payable in respect thereof. The payments of cash by Purchaser to the Company’s members in respect of each such member’s right to receive its Per
    Member Jindal Payable Amount, if any, shall be made in accordance with Section 1.1(g) herein. As soon as practicable following the Acceptance Time, the Company shall register (and shall instruct its transfer agent to register) the transfer of
    the Company Shares accepted for payment by Purchaser and shall reasonably cooperate with Purchaser to take all actions necessary to have such Company Shares transferred into Purchaser’s name on the Company’s register of members, to the extent requested
    by Purchaser.

  
    4

    
      
 

  

  (f)           Jindal Payable Consideration. For purposes of this Agreement, the following terms shall have the following
    meanings: 

   

  (i)          “Per Member Jindal Payable Amount” shall mean, with respect to a member of the
    Company, the product of the number of Company Shares tendered by such member in the Offer multiplied by the Per Share Jindal Payable Amount.

   

  (ii)          “Per Share Jindal Payable Amount” shall mean the quotient of the Aggregate Jindal
    Payable Amount divided by 5,498,686, as such number may be adjusted pursuant to Section 1.1(c).

   

  (iii)         “Aggregate Jindal Payable Amount” shall mean an amount equal to any and all cash
    proceeds actually received on or before the day prior to the day on which the Acceptance Time occurs by the Company or any of its Affiliates (a “Company Party”) from Jindal Drilling & Industries Limited or any
    of its Affiliates (collectively, “Jindal”) in whole or partial satisfaction of a certain claim a Company Party has against Jindal (the “Jindal Claim”).

   

  (g)           Timing of Jindal Consideration Payments. Payments of cash by Purchaser to the Company’s members in respect
    of each such member’s right to receive its Per Member Jindal Payable Amount, if any, and to the holder of each Company Equity Award outstanding as of the Acceptance Time with respect to each such holder’s right to receive such holder’s Equity Award
    Jindal Payment, if any, shall be made at the Acceptance Time.

   

  (h)          Treatment of Company Equity Awards. Each Company Equity Award outstanding as of the Acceptance Time shall
    immediately become 100% vested pursuant to the change of control provisions in the Company Equity Plan and the Company Equity Awards and the Company’s right to settle vested Company Equity Awards in cash on terms that the Company Equity Awards shall be
    cancelled in exchange for the right to receive (subject to applicable tax withholding) (i) an amount in cash equal to the product of US $42.28 and the number of Company Shares subject to such Company Equity Award (which the Company agrees, together
    with the Equity Award Jindal Payment, equals the Fair Market Value as defined in the Company Equity Plan, which shall be paid by the Purchaser at the Acceptance Time (the “Equity Award Cash Consideration”) and (ii) an amount in cash equal to the
    product of (A) the Per Share Jindal Payable Amount, if any, and (B) the number of Company Shares subject to such award, payable in accordance with the terms of Section 1.1(g) (the “Equity Award Jindal Payment”).

  
    5

    
      
 

  

  Section 1.2           Company Actions.

   

  (a)          Company Determinations, Approvals and Recommendations. The Company hereby approves and consents to the Offer
    and represents and warrants to Purchaser that, at a meeting duly called and held prior to the execution of this Agreement, the Company Board of Directors has, upon the terms and subject to the conditions set forth herein:

   

  (i)           approved the execution and delivery by the Company of, and the performance by the Company of
    its obligations under, this Agreement;

   

  (ii)          determined that the Offer is in the best interests of the Company and recommended that the
    holders of Company Shares accept the Offer and tender their Company Shares to Purchaser pursuant to the Offer;

   

  (iii)         approved the acquisition by Purchaser of the Company Shares pursuant to the Offer for
    purposes of Section 49(a) of the Company Articles and Section 4.02(a) of the Shareholders’ Agreement; and

   

  (iv)        resolved that, immediately following the Acceptance Time, the appointments and employment of
    all of the officers of the Company shall immediately and automatically be terminated without cause, conditioned solely upon the occurrence of the Acceptance Time and the performance by the Parties of their obligations under this Agreement.

   

  (b)         The Company hereby consents to the inclusion of the determinations, approvals and resolutions contained in Section 1.2(a)(i) through
      Section 1.2(a)(iii) in the Offer to Purchase.

   

  (c)         Company Information. In connection with the Offer, the Company shall, or shall cause its transfer agent to,
    promptly furnish Purchaser with such assistance and such information as Purchaser may reasonably request in order to disseminate and otherwise communicate the Offer to the record and beneficial holders of Company Shares. Subject to applicable Laws, and
    except for such steps as are necessary to disseminate the Offer to Purchase, Purchaser shall, hold in confidence the information provided pursuant to this section, use such information only in connection with the Offer and, if this Agreement shall be
    terminated pursuant to Article VI, promptly destroy or return to the Company any and all copies and any extracts or summaries from such information then in its possession or control.

   

  ARTICLE II

   

  REPRESENTATIONS AND WARRANTIES OF THE COMPANY

   

  Except (x) as expressly set forth in the Company Governing Documents or the Shareholders’ Agreement or (y) as disclosed in the
    disclosure letter delivered by the Company to Purchaser immediately prior to the execution of this Agreement (the “Company Disclosure Letter”), the Company represents and warrants to Purchaser as set forth below.

  
    6

    
      
 

  

  Section 2.1           Qualification; Organization; Subsidiaries; and Company Board of Directors.

   

  (a)          Each of the Company and the Company Subsidiaries (i) is a legal entity duly organized, validly existing and, where such
    concept is recognized, in good standing under the Laws of its respective jurisdiction of organization and has all requisite corporate or similar power and authority to own, lease and operate its properties and assets and to carry on its business as
    presently conducted and (ii) is qualified to do business and, where such concept is recognized, is in good standing as a foreign corporation or other entity in each jurisdiction where the ownership, leasing or operation of its assets or properties or
    conduct of its business requires such qualification, except, in the case of this clause (ii), where the failure to be so qualified as a foreign corporation or other entity or, where relevant, in good standing, would not, individually or in the
    aggregate, reasonably be expected to have a Company Material Adverse Effect.

   

  (b)          All the issued and outstanding shares of capital stock of, or other equity interests in, each Company Subsidiary have been
    validly issued and are fully paid and nonassessable and are wholly owned, directly or indirectly, by the Company free and clear of all Liens, other than Permitted Liens, as disclosed in Section 2.1(b) of the Company Disclosure Letter.

   

  (c)          Section 2.1(c) of the Company Disclosure Letter contains an accurate list, as of the date hereof, of the directors serving
    on the Company Board of Directors and the officers of the Company.

   

  (d)         As of the date hereof, each of the directors serving on the Company Board of Directors has delivered to the Company a
    conditional letter of resignation, resigning from the Company Board of Directors effective as of the Acceptance Time and conditioned solely upon the occurrence of the Acceptance Time and the performance by the Parties of their obligations under this
    Agreement.

   

  Section 2.2           Capitalization.

   

  (a)          The authorized share capital of the Company consists of 15,000,000 Company Shares. As of the date hereof, (i) (1)
    5,017,556 Company Shares were issued and outstanding, (2) no Company Shares were held in treasury and (3) no Company Shares were held by the Company Subsidiaries, and (ii) 538,000 Company Shares were reserved for issuance pursuant to the Company Equity
    Plan. All the outstanding Company Shares are duly authorized, validly issued, fully paid and non-assessable and free of pre-emptive rights and none of the Company Equity Awards have any voting rights prior to the anticipated Acceptance Time.

   

  (b)          Section 2.2(b) of the Company Disclosure Letter sets forth, as of the date hereof, (i) the aggregate number of
    Company Shares that are subject to Company Equity Awards, (ii) the name or identification number of each holder, (iii) the number of Company Shares subject to each Company Equity Award, (iv) the grant date of each Company Equity Award and (v) the
    vesting schedule of each Company Equity Award. The Company shall provide Purchaser, within three (3) Business Days prior to the anticipated Acceptance Time and again at the Acceptance Time, with an updated complete and correct list, as of each such
    date, of the information required to be set forth on Section 2.2(b) of the Company Disclosure Letter. No holder of Company Equity Awards has any voting or other rights which can or will vest before the Acceptance Time.

  
    7

    
      
 

  

  (c)          Except as set forth in Section 2.2(a) and Section 2.2(b) above, as of the date
    hereof: (i) the Company does not have any shares or other voting securities issued or outstanding or reserved for issuance, and (ii) there are no outstanding subscriptions, options, warrants, puts, calls, exchangeable or convertible securities or other
    similar rights, agreements or commitments relating to the issuance of capital stock to which the Company or any of the Company Subsidiaries is a party obligating the Company or any of the Company Subsidiaries to (1) issue, transfer or sell any shares
    in the capital or other equity interests of the Company or any Company Subsidiary or securities convertible into or exchangeable for such shares or equity interests (in each case other than to the Company or a wholly owned Subsidiary of the Company);
    (2) grant, extend or enter into any such subscription, option, warrant, put, call, exchangeable or convertible securities or other similar right, agreement or commitment; (3) redeem or otherwise acquire any such shares in its capital or other equity
    interests; or (4) provide a material amount of funds to, or make any material investment (in the form of a loan, capital contribution or otherwise) in, any Company Subsidiary that is not wholly owned.

   

  (d)         Neither the Company nor any Company Subsidiary has outstanding bonds, debentures, notes or other similar obligations, the
    holders of which have the right to vote (or which are convertible into or exercisable for securities having the right to vote) with the members of the Company on any matter.

   

  (e)        There are no voting trusts or other agreements or understandings to which the Company or any Company Subsidiary is a party
    with respect to the voting of the capital stock or other equity interest of the Company or any Company Subsidiary.

   

  Section 2.3          Company Authority.

   

  (a)        The Company has all requisite company power and authority to enter into this Agreement and to consummate the Transactions.
    The execution and delivery of this Agreement and the consummation of the Transactions have been duly and validly authorized by the Company Board of Directors and no other company proceedings on the part of the Company are necessary to authorize the
    consummation of the Transactions and the performance of the Company’s obligations under this Agreement.

   

  (b)        This Agreement has been duly and validly executed and delivered by the Company and, assuming this Agreement constitutes the
    valid and binding agreement of Purchaser, constitutes the valid and binding agreement of the Company, enforceable against the Company in accordance with its terms, except that (i) such enforcement may be subject to applicable bankruptcy, insolvency,
    examinership, reorganization, moratorium or other similar Laws, now or hereafter in effect, relating to creditors’ rights generally and (ii) equitable remedies of specific performance and injunctive and other forms of equitable relief may be subject to
    equitable defenses and to the discretion of the court before which any proceeding therefor may be brought (collectively, the “Enforceability Limitations”).

  
    8

    
      
 

  

  Section 2.4          Governmental Consents; No Violation.

   

  (a)         Other than in connection with or in compliance with (i) applicable securities Laws, and (ii) any applicable requirements of
    Antitrust Laws, no authorization, consent or approval of, or filing with, any Governmental Entity is necessary, under applicable Law, for the consummation by the Company of the Transactions, except for such authorizations, consents, approvals or
    filings that, if not obtained or made, would not reasonably be expected to have, individually or in the aggregate, a Company Material Adverse Effect.

   

  (b)          The execution and delivery by the Company of this Agreement do not, and, except as described in Section 2.4(a),
    the consummation of the Transactions and compliance with the provisions hereof will not, (i) result in any violation or breach of, or default or change of control (with or without notice or lapse of time, or both) under any contract, indenture,
    promissory note, credit facility, mortgage, pledge, security agreement or result in the creation of any Lien upon any of the properties, rights or assets of the Company or any Company Subsidiaries, other than Permitted Liens, (ii) conflict with or
    result in any violation of any provision of the Company Governing Documents or (iii) conflict with or violate any Laws applicable to the Company or any of the Company Subsidiaries or any of their respective properties or assets, other than in the case
    of clauses (i) and (iii), any such violation, conflict, default, termination, cancellation,
    acceleration, right, loss or Lien that would not reasonably be expected to have, individually or in the aggregate, a Company Material Adverse Effect.

   

  Section 2.5         Litigation. As of the date hereof, there is no claim, action, suit or proceeding, whether
    administrative, governmental, arbitrational or of another legal character, pending or, to the Company’s Knowledge, threatened by or against the Company or any Company Subsidiary before any court or arbitrator or by any Governmental Entity and neither
    the Company nor any Company Subsidiary is subject to any outstanding order, writ, injunction or decree which may interfere with the conduct of its business or the use or ownership of its assets, in each case, other than (a) as included in the Disclosed
    Information, (b) reserved for in the Company’s financial statements, or (c) such claims, actions, suits, proceedings, orders, writs, injunctions and decrees that are ordinary, routine or incidental to the Company’s business.

   

  Section 2.6          Specific Disclosures. The Disclosed Information does not contain any untrue or misleading
    statement of a material fact and all agreements provided as part of the Disclosed Information are true and complete copies thereof in all material respects. Section 2.6 of the Company Disclosure Letter sets forth a true and accurate copy of the
    following, each of which is also included in the Disclosed Information: (a) the Company’s Backlog as of January 31, 2018, (b) the unaudited, consolidated balance sheet of the Company as of January 31, 2018 and (c) the total severance payments for which
    the Company and the Company Subsidiaries would be liable, assuming all officers and employees of the Company and each Company Subsidiary were terminated as of April 1, 2018 as a result of a change of control of the Company occurring on such date.

   

  Section 2.7          Liens. Section 2.7 of the Company Disclosure Letter contains a true and accurate copy of the
    Register of Mortgages and Charges of the Company as of the date hereof.

  
    9

    
      
 

  

  Section 2.8         Finders and Brokers. Other than Deutsche Bank Securities Inc., neither the Company nor any Company
    Subsidiary has employed any investment banker, broker or finder in connection with the Transactions who might be entitled to any fee or any commission in connection with this Agreement or upon consummation of the Offer.

   

  Section 2.9          No Other Representations. Except for the representations and warranties contained in Article
      III, the Company acknowledges that neither Purchaser nor any Representative of Purchaser makes, and the Company acknowledges that it has not relied upon or otherwise been induced by, any other express or implied representation or warranty with
    respect to Purchaser or with respect to any other information provided or made available to the Company in connection with the Transactions, including any information, documents, projections, forecasts or other material made available to the Company or
    to the Company’s Representatives in expectation of the Transactions.

   

  ARTICLE III

   

  REPRESENTATIONS AND WARRANTIES OF PURCHASER 

   

  Purchaser represents and warrants to the Company as set forth below:

   

  Section 3.1          Qualification, Organization, etc. Purchaser is a Bermuda company duly organized, validly existing
    and in good standing under the Laws of its jurisdiction of organization and has all requisite company power and authority to own, lease and operate its properties and assets and to carry on its business as presently conducted and is qualified to do
    business and is in good standing as a foreign entity in each jurisdiction where the ownership, leasing or operation of its assets or properties or conduct of its business requires such qualification, except where the failure to be so organized, validly
    existing, qualified or, in good standing, or to have such power or authority, would not, individually or in the aggregate, reasonably be expected to have a Purchaser Material Adverse Effect.

   

  Section 3.2           Purchaser Authority.

   

  (a)         Purchaser has all requisite company or similar power and authority to enter into this Agreement and, to consummate the
    Transactions, including the Offer. The execution and delivery of this Agreement and the consummation of the Transactions have been duly and validly authorized by all necessary company action of Purchaser and no other company proceedings on the part of
    Purchaser are necessary to authorize the consummation of the Transactions.

   

  (b)         This Agreement has been duly and validly executed and delivered by Purchaser and, assuming this Agreement constitutes the
    valid and binding agreement of the Company, constitutes the valid and binding agreement of Purchaser, enforceable against Purchaser in accordance with its terms, subject to the Enforceability Limitations.

   

  Section 3.3          Governmental Consents; No Violation.

   

  (a)      Other than in connection with or in compliance with (i) applicable securities Laws and (ii) any applicable requirements of
    Antitrust Laws (including requirements in respect of any voluntary filings), no authorization, consent or approval of, or filing with, any Governmental Entity is necessary, under applicable Law, for the consummation by Purchaser of the Transactions,
    except for such authorizations, consents, approvals or filings that, if not obtained or made, would not reasonably be expected to have, individually or in the aggregate, a Purchaser Material Adverse Effect.

  
    10

    
      
 

  

  (b)         The execution and delivery by Purchaser of this Agreement do not, and, except as described in Section 3.3(a), the
    consummation of the Transactions and compliance with the provisions hereof will not, (i) result in any violation or breach of, or default or change of control (with or without notice or lapse of time, or both) under any material contract, indenture,
    promissory note, credit facility, mortgage, pledge, security agreement binding upon Purchaser or any Purchaser Subsidiary or result in the creation of any Lien upon any of the properties, rights or assets of Purchaser or any Purchaser Subsidiary, other
    than Permitted Liens, (ii) conflict with or result in any violation of any provision of the memorandum of association and bye-laws of Purchaser, as amended up to the date hereof or (iii) conflict with or violate any Laws applicable to Purchaser or any
    Purchaser’s Subsidiary or any of their respective properties or assets, other than in the case of clauses (i) and (iii), any such violation,
    conflict, default, termination, cancellation, acceleration, right, loss or Lien that would not reasonably be expected to have, individually or in the aggregate, a Purchaser Material Adverse Effect.

   

  Section 3.4       Availability of Financing. Purchaser is solvent and has, or will have available to it as of the
    Acceptance Time, sufficient cash to consummate the Transactions, including payment of the Tender Offer Consideration at the Acceptance Time, and the amounts set forth on Annex E and all other related fees and expenses of Purchaser.

   

  Section 3.5         Disclosed Information. Purchaser acknowledges and agrees that (a) Purchaser is a sophisticated
    entity, with knowledge and experience in the business in which the Company is engaged, (b) Purchaser has been afforded the opportunity to investigate and review the Company and its business and the Company has provided Purchaser with the Disclosed
    Information in response to Purchaser’s requests, and (c) in determining to proceed with the Offer, Purchaser is relying solely on such investigation and the representations and the warranties of Purchaser contained in Article II of this
    Agreement.

   

  Section 3.6        Finders and Brokers. Neither Purchaser nor any Purchaser Subsidiary has employed any investment
    banker, broker or finder in connection with the Transactions who might be entitled to any fee or any commission in connection with this Agreement or upon consummation of the Offer.

   

  Section 3.7        No Other Representations. Except for the representations and warranties contained in Article II,
    Purchaser acknowledges that neither the Company nor any Representative of the Company makes, and Purchaser acknowledges that it has not relied upon, any other express or implied representation or warranty with respect to the Company or any Company
    Subsidiaries or with respect to any other information provided or made available to Purchaser in connection with the Transactions, including any information, documents, projections, forecasts or other material made available to Purchaser or to
    Purchaser’s Representatives in expectation of the Transactions.  

  
    11

    
      
 

  

  ARTICLE IV

   

  COVENANTS RELATING TO CONDUCT OF BUSINESS PENDING THE OFFER

   

  Section 4.1           Conduct of Business by the Parties Pending the Acceptance Time.
    The Company agrees that between the date of this Agreement and the Acceptance Time or the date, if any, on which this Agreement is terminated pursuant to Section 6.1, except (w) as set forth in Section 4.1 of the Company Disclosure
    Letter, (x) as specifically required or contemplated by this Agreement, (y) as required by Law or (z) as consented to in writing by Purchaser (which consent shall not be unreasonably withheld, delayed or conditioned), (1) the Company shall and shall
    cause its Subsidiaries to, conduct its business in all material respects in the ordinary course of business consistent with past practice, including by using commercially reasonable efforts to preserve intact its and their present business
    organizations and to preserve its and their present relationships with customers, suppliers, Governmental Entities and other Persons with whom it and they have material business relations and (2) without limiting the generality of clause (1), the
    Company shall and, where applicable, shall cause each applicable Company Subsidiary to:

   

  (a)          maintain its assets and make capital expenditures consistent with past practice;

   

  (b)         not change its procedures for the payment of accounts payable and collection of receivables (such as cash rebates and terms
    of payment), the repayment of indebtedness or the payment of Taxes (except as may be necessary or appropriate in response to changes in applicable Tax Laws) nor its accounting practices or procedures;

   

  (c)          pay its creditors in accordance with past practices;

   

  (d)         comply in all material respects with all applicable Laws, the terms of all permits, approvals or licenses held by it and all
    agreements and undertakings by which it is bound;

   

  (e)          maintain all current insurance policies in force, pay all premiums under such policies when due, and not do, or permit to
    be done, anything which may cause any insurances to become void or voidable;

   

  (f)           file in a timely manner all requisite material Tax returns and pay all material Taxes in the ordinary course of business;

   

  (g)         not amend, nor permit the amendment of, the Company Governing Documents, the Company Equity Plan or any Company Equity
    Award, nor permit there to be any change in the composition of the Company Board of Directors such that the members thereof serving on the date hereof cease to constitute a majority of the Company Board of Directors nor amend the Shareholders’
    Agreement;

   

  (h)         not pay, make or declare any dividend or other distribution, including by way of repurchase of its own shares, other than
    (i) any such dividend or distribution to the Company or a Company Subsidiary or (ii) in connection with the transactions contemplated by the Prospector Rig Acquisition;

  
    12

    
      
 

  

  (i)          not (i) incur any indebtedness for borrowed money (ii) guarantee or secure the obligations of any Person, other than the
    Company or any Company Subsidiary, or (iii) agree or consent to the creation of any Liens (other than Permitted Liens) over any of its assets, other than, in each case, for (1) intercompany transactions or (2) transactions in the ordinary course of
    business; provided, however, that (A) the Company and any Company Subsidiary may, without Purchaser’s consent but subject to an obligation to disclose the material terms to the Purchaser, enter into
    negotiations, letters of intent, commitment letters and similar agreements with respect to financing or refinancing the Prospector Rigs provided that such negotiations, letter of intent, commitment letter or agreement does not commit the Company or any
    Company Subsidiary to any monetary or other obligation (including an obligation to enter into definitive contracts and proceed with the financing) other than a commitment, break-up, termination or similar fee equal to or less than US $2,000,000 in the
    aggregate and (B) if the Company shall have acquired direct or indirect ownership of the Prospector Rigs and the Acceptance Date shall not have occurred on or prior to April 15, 2018, then, notwithstanding anything herein to the contrary, the Company
    and any Company Subsidiary, without Purchaser’s consent, may, following such date, incur indebtedness for borrowed money in an amount up to US $130,000,000 in order to finance or refinance the Company’s direct or indirect ownership of the Prospector
    Rigs (including the Prospector Contracting Companies and any of their Affiliates acquired in connection with such financing or refinancing), and may grant Liens over the Prospector Rigs or the equity interests of, or any assets owned by, the Prospector
    Contracting Companies or any of such Affiliates and take other similar related or necessary actions in connection therewith in accordance with market practice for financing of this nature;

   

  (j)           not enter into, amend or terminate any agreement in respect of the Prospector Rigs or any other agreement which would
    adversely affect the Backlog or the cashflow from the Backlog in any material respect, other than, in each case, in connection with the transactions contemplated by Section 5.9;

   

  (k)          not make or agree to make any capital expenditure other than in the ordinary course of business;

   

  (l)           not (i) grant or announce any material increase in the wages, bonuses, incentives, pension or other benefits payable to
    any of its employees, nor establish any employee benefit plan, except as required by applicable Law or any agreement with any labor union or works council entered into before the date hereof or (ii) terminate the employment of any employee for any
    reason other than cause without the prior consent of Purchaser;

   

  (m)         not settle, release or forgive any claim or litigation or waive any right thereto, other than (i) as anticipated by the
    Settlement Agreement, (ii) in connection with the Jindal Claim or (iii) otherwise in the ordinary course of business; or

   

  (n)         not repay any indebtedness for borrowed money, other than (i) any intercompany indebtedness and (ii) as required by any
    financing agreements.

  
    13

    
      
 

  

  Section 4.2          Superior Proposal.

   

  (a)          Notwithstanding anything in this Agreement to the contrary, if, prior to the Acceptance Time, the Company Board of
    Directors determines in good faith after consultation with the Company’s outside legal and financial advisors that it has received a Superior Proposal and that the failure to take action to notify members of the terms thereof would reasonably be
    expected to be inconsistent with the directors’ fiduciary duties under applicable Law, then the Company may notify the members of the terms of the Superior Proposal provided that, in so doing, it notifies the members that the Company is not entitled to
    terminate this Agreement, nor is any Tendering Member entitled to terminate its Tender Support Agreement, in order to accept, or otherwise in connection with, the Superior Proposal.

   

  (b)         Nothing contained in this Agreement shall prohibit the Company or the Company Board of Directors from (i) complying with any
    mandatory obligations which require it to disclose to the Company’s members a position contemplated by Rule 14e-2(a) promulgated under the Exchange Act, or (ii) making any disclosure to its members if the Company Board of Directors has reasonably
    determined in good faith after consideration with the Company’s outside legal counsel that the failure to do so would be inconsistent with the director’s duties under applicable law.

   

  ARTICLE V

   

  ADDITIONAL AGREEMENTS

   

  Section 5.1          Notice of Certain Events. The Company shall give prompt notice to Purchaser, and Purchaser shall
    give prompt notice to the Company, (a) of any notice or other communication received by such Party from any Governmental Entity in connection with this Agreement, the Offer or the other Transactions, or from any Person alleging that the consent of such
    Person is or may be required in connection with the Offer or the other Transactions, if the subject matter of such communication or the failure of such Party to obtain such consent could be material to the Company or Purchaser, (b) of any legal
    proceeding commenced or, to any Party’s knowledge, threatened against, such Party or any of its Subsidiaries or Affiliates or otherwise relating to, involving or affecting such Party or any of its Subsidiaries or Affiliates, in each case in connection
    with, arising from or otherwise relating to the Offer or any other Transaction, and (c) upon becoming aware of the occurrence or impending occurrence of any event or circumstance relating to it or any of the Company Subsidiaries or the Purchaser
    Subsidiaries, respectively, which would reasonably be expected to render any of the representations or warranties of the Company set out in Article II inaccurate or have, individually or in the aggregate, a Company Material Adverse Effect or a
    Purchaser Material Adverse Effect, as the case may be, or which would reasonably be expected to prevent or materially delay or impede the consummation of the Transactions; provided, however, that the delivery of
    any notice pursuant to this Section 5.1 shall not cure any breach of any representation or warranty requiring disclosure of such matter prior to the date of this Agreement or otherwise limit or affect the remedies available hereunder to any
    Party. The failure to deliver any such notice shall not affect any of the conditions set forth in Section 1.1(a)(iv) or give rise to any right to terminate under Article VI. 

  
    14

    
      
 

  

   

  Section 5.2          Reasonable Best Efforts and Cooperation.

   

  (a)         Subject to the terms and conditions of this Agreement, each Party will use its reasonable best efforts to take, or cause to
    be taken, all actions and to do, or cause to be done, all things necessary, proper or advisable under applicable Laws to consummate the Offer and the other Transactions as soon as practicable after the date hereof, including (i) preparing and filing,
    in consultation with the other Party and as promptly as practicable and advisable after the date hereof, all documentation to effect all necessary applications, notices, petitions, filings, and other documents and to obtain as promptly as practicable
    all waiting period expirations or terminations, consents, clearances, waivers, licenses, orders, registrations, approvals, permits, and authorizations necessary or advisable to be obtained from any third party and/or any Governmental Entity in order to
    consummate the Offer or any of the other Transactions and (ii) using reasonable best efforts to take all steps as may be necessary to obtain all such waiting period expirations or terminations, consents, clearances, waivers, licenses, registrations,
    permits, authorizations, orders and approvals.

   

  (b)         Each of Purchaser and the Company shall, in connection with the efforts referenced in Section 5.2(a) to obtain all
    waiting period expirations or terminations, consents, clearances, waivers, licenses, orders, registrations, approvals, permits, and authorizations for the Transactions under any Antitrust Law, including any voluntary filing, (i) cooperate in all
    respects and consult with each other in connection with any filing or submission and in connection with any investigation or other inquiry, including any proceeding initiated by a private party, including by allowing the other Party to have a
    reasonable opportunity to review in advance and comment on drafts of filings and submissions; (ii) promptly inform the other Party of any communication received by such Party from, or given by such Party to any Governmental Entity, by promptly
    providing copies to the other Party of any such written communications, and of any material communication received or given in connection with any proceeding by a private party, in each case regarding any of the Transactions; and (iii) permit the other
    Party to review in advance any communication that it gives to, and consult with each other in advance of any meeting, substantive telephone call or conference with, any Governmental Entity, or, in connection with any proceeding by a private party, with
    any other Person, and to the extent permitted by any applicable Governmental Entity or other Person, give the other Party the opportunity to attend and participate in any in-person meetings with any Governmental Entity or other Person provided, however, that materials required to be provided pursuant to clauses (i) and (ii) may be redacted (1) to remove references concerning the valuation of Purchaser, Company or any of their Subsidiaries, (2)
    as necessary to comply with contractual arrangements, and (3) as necessary to address reasonable privilege or confidentiality concerns. If any such redactions are made, unredacted materials shall be provided to outside counsel for the other party on an
    outside counsel only basis. Notwithstanding the foregoing and Section 7.3, Purchaser shall bear and pay any and all filing fees required to be paid under any Antitrust Laws or any other filing fee paid to any Governmental Entity in connection
    with obtaining any waiting period expirations or terminations, consents, clearances, waivers, licenses, orders, registrations, approvals, permits, and authorizations from such Governmental Entity.

  
    15

    
      
 

  

  (c)         To the extent requested by Purchaser in writing at least two (2) Business Days prior to the anticipated Acceptance Time,
    the Company Board of Directors will resolve to conditionally appoint such directors as are designated by Purchaser in such writing to serve on the Company Board of Directors in order to fill the vacancies created by the resignations contemplated by Section

      2.1(d), conditioned solely upon the occurrence of the resignations contemplated by Section 2.1(d). Promptly following the effectiveness of the appointment of any such directors designated by Purchaser, including following the resignations
    of directors contemplated by Section 2.1(d), the Company will provide Purchaser with an updated register of the directors and officers of the Company.

   

  Section 5.3         Publicity. So long as this Agreement is in effect, neither the
    Company nor Purchaser, nor any of their respective Affiliates or Representatives, shall issue or cause the publication of any press release or other public announcement with respect to the Offer or this Agreement without the prior consent of the other
    Party, unless such Party determines, after consultation with outside counsel, that it is required by applicable Law or by any listing agreement with or the listing rules of a securities exchange or trading market to issue or cause the publication of
    any press release or other public announcement with respect to the Offer or this Agreement, in which event such Party shall endeavor, on a basis reasonable under the circumstances, to provide a meaningful opportunity to the other Party to review and
    comment upon such press release or other announcement in advance and shall give due consideration to all reasonable additions, deletions or changes suggested thereto; provided, however, that the Company shall
    not be required by this Section 5.3 to provide any such review or comment to the other Party in the event of any Superior Offer or any dispute between the Parties relating to this Agreement; provided, further,
    each Party and their respective Affiliates or Representatives may make statements that are not inconsistent with previous press releases, public disclosures or public statements made by Purchaser and the Company in compliance with this Section 5.3.

   

  Section 5.4          Directors’ and Officers’ Insurance and Indemnification.

   

  (a)         For not less than ten (10) years from and after the Acceptance Time, Purchaser shall, and shall cause the Company
    to, indemnify and hold harmless all past and present directors, officers and employees of the Company and the Company Subsidiaries (collectively, the “Indemnified Parties”) against any costs or expenses (including
    advancing reasonable attorneys’ fees and expenses directly to the relevant attorney in advance of the final disposition of any actual or threatened claim, suit, proceeding or investigation to each Indemnified Party to the fullest extent permitted by
    Law; provided such Indemnified Party agrees in advance in writing to return any such funds to which a court of competent jurisdiction has determined in a final, non-appealable judgment such Indemnified Party is
    not ultimately entitled), judgments, fines, losses, claims, damages, liabilities and amounts paid in settlement (on terms consented to by the Company, such consent not to be unreasonably withheld, conditioned, or delayed) in connection with any actual
    or threatened claim, action, investigation, suit or proceeding in respect of acts or omissions occurring or alleged to have occurred at or prior to the Acceptance Time (including acts or omissions occurring in connection with the approval of this
    Agreement and the consummation of the Offer or any of the other Transactions), whether asserted or claimed prior to, at or after the Acceptance Time, in connection with such persons serving as an officer, director, employee or other fiduciary of the
    Company or any of the Company Subsidiaries or of any Person if such service was at the request or for the benefit of the Company or any of the Company Subsidiaries,  to the fullest extent permitted by Law. The Parties agree that all rights to
    elimination of liability, indemnification and advancement of expenses for acts or omissions occurring or alleged to have occurred at or prior to the Acceptance Time, whether asserted or claimed prior to, at or after the Acceptance Time, now existing in
    favor of the Indemnified Parties as provided in the Company Governing Documents, the organizational documents of any Company Subsidiary or any other applicable agreement or document shall survive the consummation of the Offer and shall continue in full
    force and effect. Notwithstanding anything herein to the contrary, if any Indemnified Party notifies Purchaser or the Company on or prior to the sixth anniversary of the Acceptance Time of a matter in respect of which such Person may seek
    indemnification pursuant to this Section 5.4, the provisions of this Section 5.4 shall continue in effect with respect to such matter until the final disposition of all claims, actions, investigations, suits and proceedings relating
    thereto. 

  
    16

    
      
 

  

  (b)        For ten (10) years after the Acceptance Time, Purchaser shall cause to be maintained in effect the provisions in (i)
    the Company Governing Documents and the organizational documents of the Company Subsidiaries and (ii) any other agreements of the Company and the Company Subsidiaries with any Indemnified Party, in each case, regarding elimination of liability,
    indemnification of officers, directors and employees and advancement of expenses that are in existence on the date of this Agreement (the “Exculpation and Indemnification Agreements”), including those Exculpation
    and Indemnification Agreements listed in Section 5.4(b) of the Company Disclosure Letter; and no such provision described in clauses (i) or (ii) shall be amended, and no such provision shall be amended, modified or repealed in any manner that would
    adversely affect the rights or protections thereunder of any such Indemnified Party in respect of acts or omissions occurring or alleged to have occurred at or prior to the Acceptance Time (including acts or omissions occurring in connection with the
    approval of this Agreement and the consummation of the Offer or any of the other Transactions).

   

  (c)         At or prior to the Acceptance Time, Company shall, using Company’s current insurance broker, purchase a “tail policy” to the
    Company’s current directors’ and officers’ liability insurance policy and fiduciary liability policy or policies that provides coverage for events occurring prior to the Acceptance Time, for an aggregate period of not less than ten (10) years from the
    Acceptance Time (the “Tail Period”), for the benefit of the Company’s past and current directors and officers (the “D&O Insurance”), which tail policy shall contain the
    same coverage amounts and shall be no less favorable than the Company’s existing policy or policies or, if insurance coverage that is no less favorable is unavailable, the best available coverage; provided, however, that Purchaser shall not be required
    to pay a total premium for the D&O Insurance in excess of US $400,000 for the Tail Period. Purchaser shall cause the Company to maintain in effect such D&O Insurance in accordance with its terms throughout the Tail Period.

   

  (d)         In the event Purchaser or any of its respective successors or assigns (i) consolidates with or merges into any other Person
    and shall not be the continuing or surviving corporation or entity of such consolidation or merger or (ii) transfers all or substantially all of its properties and assets to any Person, then, and in each such case, proper provision shall be made so
    that the successors and assigns of Purchaser, as the case may be, shall assume the obligations set forth in this Section 5.4. The rights and obligations under this Section 5.4 shall survive consummation of the Offer and shall not be
    terminated or amended in a manner that is adverse to any Indemnified Party without the written consent of such Indemnified Party.

  
    17

    
      
 

  

  Section 5.5        Employee Benefits Matters.
    Following the Acceptance Time, for each Company Employee, Purchaser shall retain and perform all of its mandatory or contractual liabilities and obligations with respect to continuation coverage under COBRA except that, where there is no comparable
    beneficiary, for purposes of applying the provisions of COBRA, any reference to “similarly situated beneficiaries” (including references to “similarly situated beneficiaries with respect to whom a qualifying event has not occurred”) shall be
    interpreted to mean similarly situated employees of the Company and the Company Subsidiaries as of immediately prior to the Acceptance Time, with the benefit coverage and premiums determined based on the benefit coverage and premiums applicable to such
    similarly situated employees as in effect immediately prior to the Acceptance Time. Any COBRA reimbursements or payments due under any employment agreement to which a Company Employee is a party shall be determined based on the provisions of this Section

      5.5.

   

  Section 5.6         Employment Matters. Purchaser shall cause the Company and its
    Affiliates to comply with all requirements under Layoff Laws as of or after the Acceptance Time. Between the date of this Agreement and the Acceptance Time, if Purchaser shall determine (subject to the occurrence of the Acceptance Time) to take any
    action following the Acceptance Time that would require any notices, give rise to a consultation obligation or otherwise require action pursuant to any Layoff Laws, then Purchaser and Company shall cooperate with each other to provide any required
    notices, perform any consultation obligations and otherwise take all actions as required by any Layoff Laws in order to limit any liability or penalty, and commence any notice period, arising under any Layoff Laws.

   

  Section 5.7          Payments at the Acceptance Time. Effective simultaneously with the
    Acceptance Time (other than as expressly contemplated in Annex E), Purchaser and the Company shall pay those amounts set forth on Annex E. Promptly following the Acceptance Time, the Company will provide Purchaser with an updated
    register of mortgages and charges with respect to the Company that reflects the release of any and all Liens listed therein that were released as of the Acceptance Time.

   

  Section 5.8         Security Holder Litigation. Each Party shall provide the other
    Party prompt notice of any litigation brought by any shareholder or member, as applicable, of that Party against such Party, any of its Subsidiaries and/or any of their respective directors relating to this Agreement, the Offer or any of the other
    Transactions and shall keep the other Party informed on a prompt and timely basis with respect to the status thereof. The Company shall give Purchaser the opportunity to participate (at Purchaser’s expense) in the defense or settlement of any such
    litigation, and no such settlement shall be agreed to without Purchaser’s prior written consent, which consent shall not be unreasonably withheld or delayed, except that Purchaser shall not be obligated to consent to any settlement which does not
    include a full release of Purchaser and its Affiliates or which imposes an injunction or other equitable relief after the Acceptance Time upon Purchaser or any of its Affiliates. In the event of, and to the extent of, any conflict or overlap between
    the provisions of this Section 5.8 and Section 4.1 or Section 5.2, the provisions of this Section 5.8 shall control.

   

  Section 5.9         Prospector Rigs. The Company shall use its reasonable best efforts
    to, prior to the Acceptance Time, (a) obtain full direct, or indirect through one or more Company Subsidiaries, legal and beneficial title, free and clear from all Liens, other than Permitted Liens, to all of the Prospector Contracting Company Shares;
    (b) cause all Liens, other than Permitted Liens, on all of the respective assets of the Prospector Contracting Companies to be released and discharged; (c) cause each Prospector Contracting Company to obtain full legal and beneficial title to its
    respective Prospector Rig, free and clear from all Liens, other than Permitted Liens, as evidenced by a certificate of ownership and encumbrance from the Vanuatu ship register; (d) effect the performance of its related obligations under the Settlement
    Agreement and the Management Agreement; and (e) cause each debtor in the chapter 11 cases styled In re Prospector Offshore Drilling S.à.r.l, et al., Case No. 17-11572 (CSS) (the “Bankruptcy

      Cases”) that is acquired by the Company in connection with the Prospector Rig Acquisition, including the Prospector Contracting Companies, to be fully dismissed from the Bankruptcy Cases pursuant to an order of the bankruptcy court, the
    effectiveness of which order has not been stayed (the actions described in this Section 5.9, collectively, the “Prospector Rig Acquisition”). 

  
    18

    
      
 

  

  
  Section 5.10        Shareholders’ Agreement. Purchaser agrees that between the date of
    this Agreement and the date, if any, on which this Agreement is terminated pursuant to Section 6.1, Purchaser shall comply strictly with the terms of Section 4.03 of the Shareholders’ Agreement, and Company agrees and acknowledges that the
    terms and conditions of the Offer as set forth in this Agreement shall be deemed to constitute a “Takeover Offer” within the meaning of Section 4.03 of the Shareholders’ Agreement and to comply strictly with the terms of Section 4.03 of the
    Shareholders’ Agreement. 

   

  ARTICLE VI

   

  TERMINATION

   

  Section 6.1          Termination. This Agreement may be terminated and the Offer and
    the other Transactions may be abandoned, at any time before the Acceptance Time, as follows:

   

  (a)          by mutual written consent of Purchaser and the Company;

   

  (b)         by the Company, in the event that (i) the Company is not then in material breach of this Agreement and (ii) (1)
    Purchaser shall have materially breached its covenants or agreements under this Agreement, or (2) any of the representations and warranties of Purchaser set forth in this Agreement shall have become inaccurate, which inaccuracy would reasonably be
    expected to have a Purchaser Material Adverse Effect, in each of clauses (1) and (2) to the extent such breach, violation or inaccuracy is incapable of being cured or is not cured by Purchaser within the earlier of (x) thirty (30) calendar days
    following receipt of written notice from the Company of such breach, violation or inaccuracy or (y) the then-scheduled expiration date of the Offer (provided, for the purposes of this clause (y), Purchaser may irrevocably extend the expiration date of
    the Offer to the later of (A) the Outside Date or (B) the thirtieth calendar day after the written notice contemplated in clause (x) in order to extend the cure period);

   

  (c)         by Purchaser, in the event that (i) Purchaser is not then in material breach of this Agreement and (ii) the Company shall
    have materially breached its covenants or agreements under this Agreement, or any of the representations and warranties of the Company set forth in this Agreement shall have become inaccurate, in either case such that the conditions to the Offer set
    forth in Section 1.1(a) are not capable of being satisfied by the Outside Date;

  
    19

    
      
 

  

   

  (d)         by either Purchaser or the Company, if the Acceptance Time shall not have occurred by 11:59 p.m. New York Time on
    May 30, 2018 (the “Outside Date”); provided, however, that if the conditions set forth in Section 1.1(a)(iv)(2) or Section 1.1(a)(iv)(3) solely with respect to Antitrust Laws
    shall not have been satisfied on the Outside Date, the Outside Date may be extended by either Party, by written notice to the other Party, up to a date not beyond June 30, 2018; provided, further, that the right
    to terminate this Agreement pursuant to this Section 6.1(d) shall not be available to any Party whose action or failure to fulfill any obligation under this Agreement proximately caused any of the Offer Conditions having failed to be satisfied
    and such action or failure to act constitutes a material breach of this Agreement; or

   

  (e)         by either the Company or Purchaser if a Governmental Entity of competent jurisdiction shall have issued a final,
    non-appealable order, injunction, decree or ruling in each case permanently restraining, enjoining or otherwise prohibiting the consummation of the Offer.

   

  Section 6.2          Effect of Termination.

   

  (a)         Save as regulated by Section 6.2(b), in the event of the valid termination of this Agreement as provided in
    Section 6.1, written notice thereof shall forthwith be given to the other Party or Parties specifying the provision hereof pursuant to which such termination is made, and this Agreement shall forthwith become null and void and there shall be no
    liability on the part of Purchaser or the Company, other than any liability for a Willful Breach of this Agreement prior to such termination, which the Parties acknowledge and agree shall not be limited to reimbursement of expenses or out-of-pocket
    costs.

   

  (b)        If the Company terminates this Agreement pursuant to (i) Section 6.1(b) or (ii) Section 6.1(d) but,
    with respect to this clause (ii) only if (1) all of the Offer Conditions have been satisfied or waived, but the Acceptance Time has not occurred as of the Outside Date as a result of Purchaser’s breach of, or failure to fulfill its obligations under, Section

      1.1(e) and Section 1.1(g) to accept for payment and pay for all Company Shares that are validly tendered and not withdrawn in the Offer or (2) Purchaser’s action or failure to fulfill any obligation under this Agreement proximately caused
    any of the Offer Conditions having failed to be satisfied and such action or failure to act constitutes a material breach of this Agreement, then, in each case, the Purchaser shall be liable to the Company in an amount equal to US $10,000,000, payable
    in cash by wire transfer of immediately available funds (the “Termination Payment”) as the Company’s sole and exclusive remedy and as full and complete satisfaction of any liabilities that may be suffered by the
    Company hereunder. It is expressly stipulated by the Parties that the actual amount of damages resulting from such a termination would be difficult if not impossible to determine accurately because of the unique nature of this Agreement, the unique
    nature of the Company Shares, the uncertainties of applicable commodity markets, and differences of opinion with respect to such matters, and that the liquidated damages associated with the payment of the Termination Payment to the Company is a
    reasonable estimate by the Parties of such damages under the circumstances and does not constitute a penalty.

   

  (c)          The Confidentiality Agreement, this Section 6.2 and Section 7.3 through Section 7.12 shall survive
    termination of this Agreement.

   

  
    20

    
      
 

  

  ARTICLE VII

   

  MISCELLANEOUS

   

  Section 7.1          Amendment and Modification; Waiver.

   

  (a)         Subject to applicable Law and except as otherwise provided in this Agreement, this Agreement may be amended,
    modified and supplemented only by written agreement signed by each of the Parties.

   

  (b)         At any time and from time to time prior to the Acceptance Time, either the Company, on the one hand, or Purchaser,
    on the other hand, may, to the extent legally allowed and except as otherwise set forth herein, (i) extend the time for the performance of any of the obligations or other acts of Purchaser, in the case of an extension by the Company, or of the Company,
    in the case of an extension by Purchaser, as applicable, (ii) waive any inaccuracies in the representations and warranties made to such Party contained herein or in any document delivered pursuant hereto, and (iii) waive compliance with any of the
    agreements or conditions for the benefit of any such Party contained herein. Any agreement on the part of Purchaser or the Company to any such extension or waiver shall be valid only if set forth in an instrument in writing signed on behalf of
    Purchaser or the Company, as applicable. Any delay in exercising any right under this Agreement shall not constitute a waiver of such right.

   

  Section 7.2         Non-Survival of Representations and Warranties. None of the
    representations and warranties in this Agreement or in any schedule, instrument or other document delivered pursuant to this Agreement shall survive the Acceptance Time. This Section 7.2 shall not limit any covenant or agreement of the Parties
    which by its terms contemplates performance after the Acceptance Time.

   

  Section 7.3          Expenses. Except as otherwise expressly provided in this
    Agreement, all Expenses incurred in connection with this Agreement and the Transactions shall be paid by the Party incurring such Expenses.

   

  Section 7.4         Notices. All notices and other communications hereunder
    shall be in writing and shall be deemed given if delivered personally (notice deemed given upon receipt), sent by facsimile (notice deemed given upon confirmation of transmission if sent before or during the regular business hours of the recipient or
    on the next Business Day if sent after the regular business hours of the recipient), sent by email (notice deemed given upon confirmation of receipt) or sent by a nationally recognized overnight courier service, such as Federal Express (notice deemed
    given upon receipt of proof of delivery), to the Parties at the following addresses (or at such other address for a Party as shall be specified by like notice):

   

  if to Purchaser, to:

   

  Borr Drilling Limited

  Thistle House 

  4 Burnaby Street

  Hamilton 

  HM11 

  Bermuda 

  Attention: Simon Johnson CEO 

  Email: sjohnson@borrdrilling.com

  Facsimile: +1 441 292 2277

  
    21

    
      
 

  

  with a copy to:

   

  Ro Sommernes Advokatfirma DA

  Fridjof Nansens plass 7 

  Oslo

  Norway 

  Attention; Erling Lind 

  Email: el@rosom.no

   

  and

   

  if to the Company, to: 

  

  

  Paragon Offshore Limited 

  3151 Briarpark Drive 

  Suite 700 

  Houston, TX 77042 

  Attention: Todd Strickler 

  Email: tstrickler@paragonoffshore.com

   

  with a copy to (which shall not constitute notice) to: 

  

  

  Vinson & Elkins LLP 

  1001 Fannin Street 

  Suite 2500 

  Houston, TX 77002 

  Attention: Michael S. Telle, Esq.

  Email: mtelle@velaw.com

  Facsimile: (713) 615-5651

   

  Section 7.5       Interpretation. When a reference is made in this Agreement to
    Sections, such reference shall be to a Section of this Agreement unless otherwise indicated. Whenever the words “include”, “includes” or “including” are used in this Agreement they shall be deemed to be followed by the words “without limitation”. The
    table of contents and headings set forth in this Agreement are for convenience of reference purposes only and shall not affect or be deemed to affect in any way the meaning or interpretation of this Agreement or any term or provision hereof. All
    references herein to the Subsidiaries of a Person shall be deemed to include all direct and indirect Subsidiaries of such Person unless otherwise indicated or the context otherwise requires. The Parties agree that they have been represented by counsel
    during the negotiation and execution of this Agreement and, therefore, waive the application of any Law, regulation, holding or rule of construction providing that ambiguities in an agreement or other document will be construed against the party
    drafting such agreement or document. 

  
    22

    
      
 

  

   

  Section 7.6        Counterparts. This Agreement may be executed manually or by
    facsimile by the Parties, in any number of counterparts, each of which shall be considered one and the same agreement and shall become effective when a counterpart hereof shall have been signed by each of the Parties and delivered to the other Parties.

   

  Section 7.7          Entire Agreement; Third-Party Beneficiaries.

   

  (a)        This Agreement (including the Company Disclosure Letter) and the Confidentiality Agreement constitute the entire
    agreement among the Parties with respect to the subject matter hereof and thereof and supersede all other prior agreements (except that the Confidentiality Agreement shall be deemed amended hereby so that until the termination of this Agreement in
    accordance with Section 6.1 hereof, Purchaser shall be permitted to take the actions contemplated by this Agreement) and understandings, both written and oral, among the Parties or any of them with respect to the subject matter hereof and
    thereof.

   

  (b)         Except as provided in Section 5.4 and Section 5.6 nothing in this Agreement (including the Company Disclosure
    Letter), express or implied, is intended to confer upon any Person other than the Parties any rights or remedies hereunder.

   

  Section 7.8        Severability. If any term or other provision of this
    Agreement is invalid, illegal or incapable of being enforced by rule of Law or public policy, all other conditions and provisions of this Agreement shall nevertheless remain in full force and effect so long as the economic or legal substance of the
    Offer is not affected in any manner adverse to any Party. Upon such determination that any term or other provision is invalid, illegal or incapable of being enforced, the Parties shall negotiate in good faith to modify this Agreement so as to effect
    the original intent of the Parties as closely as possible in an acceptable manner to the end that the Offer is fulfilled to the extent possible.

   

  Section 7.9          Governing Law; Jurisdiction.

   

  (a)         THIS AGREEMENT SHALL BE GOVERNED BY, AND CONSTRUED IN ACCORDANCE WITH, THE LAWS OF THE STATE OF DELAWARE,
    APPLICABLE TO CONTRACTS EXECUTED IN AND TO BE PERFORMED ENTIRELY WITHIN THAT STATE, REGARDLESS OF THE LAWS THAT MIGHT OTHERWISE GOVERN UNDER APPLICABLE PRINCIPLES OF CONFLICTS OF LAWS.

  
    23

    
      
 

  

   

  (b)         Each of the parties to this Agreement in express reliance on Delaware Code, title 6, section 2708, (i) irrevocably
    submits itself to the personal jurisdiction of the Delaware Court of Chancery (or in the event, but only in the event, that such court does not have subject matter jurisdiction over such action or proceeding, in the United States District Court for the
    District of Delaware) in the event any dispute arises out of this Agreement or the Transactions, (ii) agrees that this jurisdiction is exclusive and that it will not attempt to deny or defeat such jurisdiction by motion or other request for leave from
    any such court and (iii) agrees that it will not bring any action relating to this Agreement or the Transactions in any court other than the Delaware Court of Chancery (or in the event, but only in the event, that such court does not have subject
    matter jurisdiction over such action or proceeding, in the United States District Court for the District of Delaware), and that the agreements in this Section 7.9 shall be a defense to jurisdiction in any other forum. The parties to this
    Agreement agree that a final judgment in any action or proceeding brought shall be conclusive and may be enforced in other jurisdictions by suit on the judgment or in any other manner provided by applicable law. Each of the parties to this Agreement
    hereby irrevocably waives, and agrees not to assert, by way of motion, as a defense, counterclaim or otherwise, in any action or proceeding with respect to this Agreement, (1) any claim that it is not personally subject to the jurisdiction of the
    above-named courts for any reason other than the failure to serve in accordance with this Section 7.9, (2) any claim that it or its property is exempt or immune from jurisdiction of any such court or from any legal process commenced in such
    courts (whether through service of notice, attachment prior to judgment, attachment in aid of execution of judgment, execution of judgment or otherwise) and (3) to the fullest extent permitted by applicable law, any claim that (A) the suit, action or
    proceeding in such court is brought in an inconvenient forum, (B) the venue of such suit, action or proceeding is improper or (C) this Agreement, or the subject matter of this Agreement, may not be enforced in or by such courts. Each of the parties to
    this Agreement hereby consents to service being made through the notice procedures set forth in Section 7.4 and agrees that service of any process, summons, notice or document by registered mail (return receipt requested and first-class postage
    prepaid) to the respective addresses set forth in Section 7.4 shall be effective service of process for any suit or proceeding in connection with this Agreement or the Transactions. The consents to jurisdiction set forth in this Section
      7.9(b) shall not constitute general consents to service of process in the State of Delaware and shall have no effect for any purpose except as provided in this Agreement and shall not be deemed to confer rights on any Person other than the
    parties to this Agreement. 

   

  (c)        Each of the Parties hereby irrevocably appoints The Corporation Trust Company, Corporation Trust Center, 1209 Orange
    Street, Wilmington, Delaware 19801 (the “Process Agent”) to receive, for it and on its behalf, service of process in any proceedings and consents to receive notice of service of process through service on the
    Process Agent. If for any reason the Process Agent is unable to act as such for a Party, the applicable Party shall, within thirty (30) days, appoint a substitute Process Agent located in the State of Delaware and give notice of such appointment to the
    other Party.

   

  Section 7.10       Waiver of Jury Trial. EACH PARTY TO THIS AGREEMENT HEREBY
    WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY RIGHT IT MAY HAVE TO A TRIAL BY JURY IN RESPECT OF ANY SUIT, ACTION OR OTHER PROCEEDING ARISING OUT OF THIS AGREEMENT OR THE TRANSACTIONS. EACH PARTY TO THIS AGREEMENT (I) CERTIFIES THAT NO
    REPRESENTATIVE OF THE OTHER PARTY HAS REPRESENTED, EXPRESSLY OR OTHERWISE, THAT SUCH PARTY WOULD NOT, IN THE EVENT OF ANY ACTION, SUIT OR PROCEEDING, SEEK TO ENFORCE THE FOREGOING WAIVER AND (II) ACKNOWLEDGES THAT IT AND THE OTHER PARTY HERETO HAVE
    BEEN INDUCED TO ENTER INTO THIS AGREEMENT, BY, AMONG OTHER THINGS, THE MUTUAL WAIVER AND CERTIFICATIONS IN THIS SECTION 7.10.

   

  Section 7.11      Assignment. This Agreement shall not be assigned by either of
    the Parties (whether by operation of Law or otherwise) without the prior written consent of the other Party, which consent shall not be unreasonably withheld. Subject to the foregoing, but without relieving any Party of any obligation hereunder, this
    Agreement will be binding upon, inure to the benefit of and be enforceable by the Parties and their respective successors and assigns. 

  
    24

    
      
 

  

   

  Section 7.12       Enforcement; Remedies.

   

  (a)         Except as otherwise expressly provided herein, any and all remedies herein expressly conferred upon a Party will be
    deemed cumulative with and not exclusive of any other remedy conferred hereby, or by Law or equity upon such Party, and the exercise by a Party of any one remedy will not preclude the exercise of any other remedy.

   

  (b)         The Parties agree that irreparable injury will occur in the event that any provision of this Agreement is not
    performed in accordance with its specific terms or is otherwise breached. It is agreed that prior to the valid termination of this Agreement pursuant to Article VI, each Party shall be entitled to an injunction or injunctions to prevent or
    remedy any breaches or threatened breaches of this Agreement by the other Party, to a decree or order of specific performance specifically enforcing the terms and provisions of this Agreement and to any further equitable relief.

   

  (c)         The Parties’ rights in this Section 7.12 are an integral part of the Transactions and each Party hereby
    waives any objections to any remedy referred to in this Section 7.12 (including any objection on the basis that there is an adequate remedy at Law or that an award of such remedy is not an appropriate remedy for any reason at Law or equity).
    Each Party agrees that there is not an adequate remedy at Law for a breach of this Agreement by a Party. In the event any Party seeks any remedy referred to in this Section 7.12, such Party shall not be required to obtain, furnish, post or
    provide any bond or other security in connection with or as a condition to obtaining any such remedy.

   

  [Signature Page Follows]

  
    25

    
      
 

  

  
  IN WITNESS WHEREOF, the Parties have executed this Agreement as of the date first above written. 

   

  
    	
             

          	PURCHASER: 
	 	 
	 	BORR DRILLING LIMITED

          
	 	 
	
             

          	
            By

          	
            

            

          
	
             

          	
            Name: 

          	
            Svedn A. Maier 

          
	 	Title: 	COO
	 	 
	 	COMPANY:
	 	 
	 	PARAGON OFFSHORE LIMITED

          
	 	  
	 	By:	

          
	 	Name: James W. Swent

          
	 	Title: Chief Executive  Officer

          

  

  

    Signature Page to Tender Offer Agreement 

  
    
      
 

  

  
  Annex A

   

  Certain Defined Terms

   

  For the purposes of this Agreement, the term:

   

  “Antitrust Laws” mean any antitrust, competition or trade regulation Laws that are
    designed or intended to prohibit, restrict or regulate actions having the purpose or effect of monopolization or restraint of trade or lessening competition through merger or acquisition.

   

  “Affiliates” means, with respect to any Person, all Persons directly or indirectly
    controlling, controlled by or under common control with such Person, in each case where the term “control” means possession, directly or indirectly, or the power to direct or cause the direction of the management and policies of an entity, whether
    through ownership of voting securities, by contract interest or otherwise.

   

  “Backlog” means expected future revenues of the Company and the Company Subsidiaries
    from existing customer contracts and letters of intent.

   

  “Business Day” means any day, other than Saturday, Sunday or a U.S. federal, Oslo,
    Norway, London, England or Cayman Island holiday, and shall consist of the time period from 12:01 a.m. through 12:00 midnight Eastern time. In computing any time period, the date of the event which begins the running of such time period shall be
    included except that if such event occurs on other than a Business Day such period shall begin to run on and shall include the first Business Day thereafter.

   

  “COBRA” means the Consolidated Omnibus Budget Reconciliation Act of 1986, as amended or
    any similar state or local law.

   

  “Company Articles” means the Amended and Restated Articles of Association of the
    Company, as in effect as of the date of this Agreement.

   

  “Company Employee” means each individual employed by the Company or a Company Subsidiary
    immediately prior to the Acceptance Time.

   

  “Company Equity Awards” means any and all Awards, as such term is defined in the Company
    Equity Plan, outstanding as of immediately prior to the Acceptance Time.

   

  “Company Equity Plan” means the Company Long Term Incentive Plan, effective as of
    December 8, 2017, as the same may be amended, restated or supplemented from time to time.

   

  “Company Governing Documents” means the Amended and Restated Memorandum of the Company,
    as in effect as of the date of this Agreement, and the Company Articles.

  
    Annex A-1

    
      
 

  

  
   

  “Company Material Adverse Effect” means any Effect that, individually or in the
    aggregate, alone or in conjunction with Effects has or would reasonably be expected to have a material adverse effect on the condition (financial or otherwise), business, assets or operations of the Company and the Company Subsidiaries, taken as a
    whole; provided, however, that no Effects resulting or arising from the following shall be deemed to constitute a Company Material Adverse Effect or shall be taken into account when determining whether a Company
    Material Adverse Effect exists or has occurred or is reasonably likely to exist or occur: (a) any changes in general global economic conditions or the general economic conditions of any country, (b) conditions (or changes therein) in any industry or
    industries in which the Company operates, including changes in global or regional oil and natural gas prices, (c) general legal, tax, economic, political and/or regulatory conditions (or changes therein), including any changes affecting financial,
    credit or capital market conditions, (d) any adoption, implementation, promulgation, repeal, modification, amendment, reinterpretation, change or proposal of any applicable Law of or by any Governmental Entity, (e) any actions expressly required by, or
    the failure to take any action expressly prohibited by, the terms of this Agreement, (f) any failure by the Company to meet any internal or published projections, estimates or expectations of the Company’s revenue, earnings or other financial
    performance or results of operations for any period, in and of itself, or any failure by the Company to meet its internal budgets, plans or forecasts of its revenues, earnings or other financial performance or results of operations, in and of itself
    (it being understood that the facts or occurrences giving rise or contributing to such failure that are not otherwise excluded from the definition of a “Company Material Adverse Effect” may be taken into account), (g) Effects arising out of changes in
    geopolitical conditions, acts of terrorism or sabotage, war (whether or not declared), the commencement, continuation or escalation of a war, acts of armed hostility, weather conditions or other force majeure events, including any material worsening of
    such conditions threatened or existing as of the date of this Agreement, (h) any matter disclosed in the Company Disclosure Letter, (i) the execution and delivery of this Agreement or the consummation of the Transactions, or the public announcement of
    this Agreement or the Transactions, including any litigation arising out of or relating to this Agreement or the Transactions or the events leading thereto (provided that this clause (i) shall not apply
    to any representation or warranty to the extent the purpose of such representation or warranty is to address the consequences resulting from the execution and delivery of this Agreement or the consummation of the Transactions) and (j) any action or
    failure to take any action that is consented to or requested by Purchaser in writing, provided that with respect to the exceptions set forth in clauses (a), (b), (c), (d) and (g), such Effect shall be taken into account in the determination of whether a Company Material Adverse Effect has occurred solely to the extent that such Effect disproportionately affected the Company relative to other
    participants in the industry in which the Company operates. 

   

  “Company Subsidiaries” means the Subsidiaries of the Company.

   

  “Company’s Knowledge” will be deemed to be, as the case may be, the actual knowledge of
    the Persons listed in Section A-1 of the Company Disclosure Letter.

   

  “Confidentiality Agreement” means the Confidentiality Agreement, dated November 6, 2017,
    between Purchaser and the Company, as amended.

   

  “Disclosed Information” means the documents, agreements and materials delivered by the
    Company to Purchaser at Purchaser’s request, a substantially complete set of which is included in the online repository to which the Company provided Purchaser access prior to the date of this Agreement.

  
    Annex A-2

    
      
 

  

  “Effect” means any change, effect, development, circumstance, condition, state of facts,
    event or occurrence.

   

  “Exchange Act” means the United States Securities Exchange Act of 1934, as amended.

   

  “Expenses” means all reasonable out-of-pocket expenses (including all fees and expenses
    of counsel, financing sources, accountants, investment bankers, experts and consultants to a Party and its Affiliates) incurred by a Party or on its behalf in connection with or related to the authorization, preparation, negotiation, execution and
    performance of this Agreement, and all other matters related to the closing of the Offer and the other Transactions.

   

  “Governmental Entity” means (a) any national, federal, state, county, municipal, local,
    or foreign government or any entity exercising executive, legislative, judicial, regulatory, taxing, or administrative functions of or pertaining to government, (b) any public international governmental organization, or (c) any agency, division,
    bureau, department, or other political subdivision of any government, entity or organization described in the foregoing clauses (a) or (b) of this definition.

   

  “Law” means any law, requirement, statute, code, rule, regulation, order, ordinance,
    judgment or decree or other pronouncement of any Governmental Entity.

   

  “Layoff Laws” means applicable Laws related to plant closings, relocations, mass
    layoffs, redundancies, collective consultation and employment terminations.

   

  “Lien” means any lien, pledge, hypothecation, mortgage, security interest, encumbrance,
    claim, option, right of first refusal, preemptive right, community property interest or restriction of any nature (including any restriction on the voting of any security, any restriction on the transfer of any security or other asset, or any
    restriction on the possession, exercise or transfer of any other attribute of ownership of any asset).

   

  “Management Agreement” means the Management Agreement dated July 18, 2017 among Paragon
    Offshore plc (in administration), the Company and Neville Kahn and David Soden as administrators, as amended by that certain Amendment Agreement dated July 20, 2017, and as may be further amended in connection with the Prospector Rig Acquisition.

   

  “member” means members of the Company or beneficial owners of Company Shares, as
    appropriate.

   

  “Permitted Liens” means any Lien (a) for Taxes or governmental assessments, charges or
    claims of payment not yet due and payable or are being contested in good faith through appropriate proceedings and for which adequate accruals or reserves have been established, (b) which is a carriers’, warehousemen’s, mechanics’, materialmen’s,
    repairmen’s or other similar Lien, or a purchase money Lien, in each case, arising in the ordinary course of business, (c) which is disclosed in the Company’s balance sheet attached to Section 2.6 of the Company Disclosure Letter or notes thereto or
    securing liabilities reflected on such balance sheet, (d) with respect to any equity interests or other securities, imposed by any applicable securities laws or contained in the governing documents of any such applicable entity, (e) imposed by the
    terms and conditions of any vendor, supplier or customer contract entered into in the ordinary course of business or of any license, permit or other consent issued or granted by a Governmental Entity, (f) in favor of or at the behest of Purchaser or
    otherwise arising pursuant to the terms of this Agreement or any of the Transactions, (g) which is not material in amount and would not reasonably be expected to materially impair the continued use of the applicable property for the purposes for which
    the property is currently being used or (h) disclosed in Section A-2 of the Company Disclosure Letter.

  
    Annex A-3

    
      
 

  

   

  “Person” means a natural person, partnership,
    corporation, limited liability company, business trust, joint stock company, trust, unincorporated association, joint venture, Governmental Entity or other entity or organization.

   

  “Prospector Contracting Companies” means Prospector Rig 1 Contracting Company S.à.r.l.
    and Prospector Rig 5 Contracting Company S.à.r.l.

   

  “Prospector Contracting Company Shares” means all of the equity interests in the
    Prospector Contracting Companies.

   

  “Prospector Rigs” means the self-elevating Friede and Goldman JU-2000E (2013) and Friede
    and Goldman JU-2000E (2014) prospector rigs.

   

  “Purchaser Material Adverse Effect” means any Effect that, individually or in the
    aggregate, has a material adverse effect on the ability of the Company or Purchaser to perform its obligations under this Agreement or to consummate timely the Transactions.

   

  “Purchaser Subsidiaries” means the Subsidiaries of Purchaser.

   

  “Representatives” means, when used with respect to any Person, the directors, officers,
    employees, consultants, financial advisors, accountants, legal counsel, investment bankers, and other agents, advisors and representatives of such Person and its Subsidiaries.

   

  “Settlement Agreement” means that certain Settlement Agreement entered into as of
    February 14, 2018 by and among Paragon Offshore plc (in administration), Prospector Offshore Drilling S.à.r.l., the Prospector Contracting Companies, Prospector One Corporation, Prospector Five Corporation, SinoEnergy Capital Management, Ltd., Paragon
    Offshore Limited and Neville Kahn and David Soden, as administrators.

   

  “Shareholders’ Agreement” means the Shareholders’ Agreement of the Company dated as of
    July 18, 2017.

   

  “Subsidiary” means, with respect to any Person, any corporation, limited liability
    company, partnership or other organization, whether incorporated or unincorporated, of which (a) at least a majority of the outstanding shares of capital stock of, or other equity interests, having by their terms ordinary voting power to elect a
    majority of the board of directors or others performing similar functions with respect to such corporation or other organization is directly or indirectly owned or controlled by such Person or by any one or more of its Subsidiaries, or by such Person
    and one or more of its Subsidiaries or (b) with respect to a partnership, such Person or any other Subsidiary of such Person is a general partner of such partnership.

  
    Annex A-4

    
      
 

  

   

  “Superior Proposal” means an unsolicited offer, proposal or indication of interest
    relating to a transaction or series of related transactions (other than the Transactions) involving (a) any acquisition or purchase by any Person or group, directly or indirectly, of Company Shares, (b) any merger, consolidation, share exchange,
    business combination, joint venture, recapitalization, reorganization or similar transaction involving the Company or (c) any sale, lease (other than in the ordinary course of business), exchange, transfer, or other disposition to a Person or group of
    Persons of assets, in each case, which the Company Board of Directors determines in good faith after consultation with the Company’s outside legal and financial advisors to be more favorable to the members than the Offer, taking into account all
    relevant factors (including all the terms and conditions of such offer, proposal or indication of interest and this Agreement).

   

  “Taxes” means any and all taxes, levies, duties, tariffs, imposts and other similar
    charges and fees imposed by any Governmental Entity or domestic or foreign taxing authority, including, income, franchise, windfall or other profits, gross receipts, premiums, property, sales, use, net worth, capital stock, payroll, employment, social
    security, workers’ compensation, unemployment compensation, excise, withholding, ad valorem, stamp, transfer, value-added, gains tax and license, registration and documentation fees, severance, occupation, environmental, customs duties, disability,
    real property, personal property, registration, alternative or add-on minimum, or estimated tax, including any interest, penalty, additions to tax or additional amounts imposed with respect thereto, whether disputed or not.

   

  “Transactions” means the transactions contemplated by this Agreement.

   

  “Willful Breach” means a deliberate act or a deliberate failure to act, taken or not
    taken with the actual knowledge that such act or failure to act constitutes in and of itself a material breach of this Agreement, regardless of whether breaching was the object of the act or failure to act.

   

  Terms Defined Elsewhere. The following terms are defined elsewhere in this
    Agreement, as indicated below:

   

  	
          Acceptance Time

        	
          Section 1.1(e)

        
	
          Aggregate Jindal Payable Amount

        	
          Section 1.1(f)(iii)

        
	
          Agreement

        	
          Preamble

        
	
          Bankruptcy Cases

        	
          Section 5.9

        
	
          Company

        	
          Preamble

        
	
          Company Board of Directors

        	
          Recitals

        
	
          Company Board Recommendation

        	
          Recitals

        
	
          Company Disclosure Letter

        	
          Article II

        
	
          Company Party

        	
          Section 1.1(f)(iii)

        
	
          Company Shares

        	
          Recitals

        
	
          D&O Insurance

        	
          Section 5.4(c)

        
	
          Enforceability Limitations

        	
          Section 2.3(b)

        
	
          Equity Award Cash Consideration

        	
          Section 1.1(h)

        
	
          Equity Award Jindal Payment

        	
          Section 1.1(h)

        
	
          Exculpation and Indemnification Agreements

        	
          Section 5.4(b)

        
	
          Indemnified Parties

        	
          Section 5.4(a)

        

   

  
    Annex A-5

    
      
 

  

  

  

  
  	
          Jindal

        	
          Section 1.1(f)(iii)

        
	
          Jindal Claim

        	
          Section 1.1(f)(iii)

        
	
          Offer

        	
          Recitals

        
	
          Offer Conditions

        	
          Section 1.1(a)(iv)

        
	
          Offer to Purchase

        	
          Section 1.1(a)(iii)

        
	
          Outside Date

        	
          Section 6.1(d)

        
	
          Party

        	
          Preamble

        
	
          Per Member Jindal Payable Amount

        	
          Section 1.1(f)(i)

        
	
          Per Share Jindal Payable Amount

        	
          Section 1.1(f)(ii)

        
	
          Process Agent

        	
          Section 7.9(c)

        
	
          Prospector Rig Acquisition

        	
          Section 5.9

        
	
          Purchaser

        	
          Preamble

        
	
          Purchaser Disclosure Letter

        	
          Article III

        
	
          Tail Period

        	
          Section 5.4(c)

        
	
          Tender Offer Consideration

        	
          Section 1.1(a)(ii)

        
	
          Tendering Members

        	
          Recitals

        
	
          Termination Payment

        	
          Section 6.2(b)

        

   

  
    Annex A-6

    
      
 

  

  
  

  
  Annex B

   

  List of Tendering Members

   

  

  The information contained on this page has been redacted for confidentiality purposes.

   

  

  
    Annex B-1

    
      

  

  
    The information contained on this page has been redacted for confidentiality purposes.

  

   

  
    Annex B-2

    
      
 

  

  
  The information contained on this page has been redacted for confidentiality purposes, other than the totals listed below.

   

  

  

  	
          Total

        	3,407,072    

          

        	67.90%    

          

        

  

  

   

  

  *Percentages are rounded off to the nearest second decimal point and are calculated based on 5,017,556 total outstanding Shares as of the date hereof. 

  
    Annex B-3

    
      
 

  

  
  Annex C

   

  Form of Offer to Purchase

  

  

  (see attached)

   

  

  The attachment to this Annex C has been intentionally omitted.

   

  
    Annex C-1

    
      
 

  

  
  Annex D

   

  Rig Delivery Protocol

   

  On the date falling 5 days before the agreed date for the Acceptance Time and again immediately prior to the Acceptance Time,
    the Company shall provide Purchaser with responses to each of the following inquiries from the rig manager of each of the Prospector Rigs via electronic mail (from a company or ship email address):

   

  
    	
            

            

          	
            (1)

          	
            Confirmation that each of the Prospector Rigs is in good working order and in class, as evidenced by a declaration of class or class
              maintenance certificate, free of material recommendations and conditions affecting class:

          

  

   

  (i)           the Prospector Rig, commonly referred to as Prospector
    1, in ABS Class, ✠ A1, Self-Elevating Drilling Unit and

   

  (ii)          (ii) the Prospector Rig, commonly referred to as Prospector 5, in ABS Class, ✠ A1,
    Self-Elevating Drilling Unit, ✠ CDS;

   

  
    	
            

            

          	
            (2)

          	
            The then-current location of such Prospector Rig;

          

  

   

  
    	
            

            

          	
            (3)

          	
            The then-current operational status of such Prospector Rig - whether drilling, under tow or stacked (warm or cold); and

          

  

   

  
    	
            

            

          	
            (4)

          	
            Whether any incident has incurred in respect of either of the Prospector Rigs that triggers a reporting obligation to the mortgagee,
              ABS, the insurers/P&I Club and/or the flag registry and/or which does (or would with the passage of time or giving of notice) constitute a default under any customer contract in force in respect of the Prospector Rigs.

          

  

  
    Annex D-1

    
      
 

  

  
  

  
  Annex E

   

  Closing Payments

   

  

  The contents of, and schedule to, this Annex E have been intentionally omitted.

   

   

  Annex E-1

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00297-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00297-of-00352.parquet"}]]