Document:

EXHIBIT 10.16

       

    

    
      FOURTH AMENDMENT TO LEASE

       

      	I.	
              PARTIES AND DATE.

            

       

      This Fourth Amendment to Lease (“Amendment”) dated May 3, 2018, is by and between DISCOVERY
        BUSINESS CENTER LLC, a Delaware limited liability company (“Landlord”), and GHOST MANAGEMENT GROUP, LLC, a Delaware limited liability company (“Tenant”).

       

      	II.	
              RECITALS.

            

       

      On November 11, 2013, Landlord and Tenant entered into a lease for space in a building located at 41 Discovery, Irvine, California (“41 Discovery Premises” and “41 Discovery Building”), which lease was amended by a First Amendment to Lease dated January 27, 2016 (“First Amendment”), wherein Tenant added approximately 4,182 rentable square feet of space in a building located at 15420 Laguna Canyon Road, Suite 260, Irvine, California (“Laguna Canyon Premises” and “Laguna Canyon Building”) to the Premises, by a Second Amendment to Lease dated April 7, 2017, wherein
        Tenant added approximately 7,000 rentable square feet of space in a building located at 49 Discovery, Suite 200, Irvine, California {“49 Discovery Premises”) to the Premises, and by a
        Third Amendment to Lease dated December 29, 2017 (“Third Amendment”), wherein Tenant terminated its leasing of the Laguna Canyon Premises and the 49 Discovery Premises in exchange for
        leasing approximately 31,407 rentable square feet of space in a building located at 43 Discovery, Suite 200, Irvine, California, and herein referred to as the “43 Discovery Premises”. The
        foregoing lease, as so amended, is hereinafter referred to as the “Lease”.

       

      Landlord and Tenant each desire to make such modifications as are set forth in “Ill. MODIFICATIONS” next below.

       

      	III.	
              MODIFICATIONS.

            

       

      A.          Work
            Letter Modifications. Landlord and Tenant desire that the architectural design services for the Tenant Improvements for the 43 Discovery Premises be performed by an architect selected and retained by Tenant (not by Landlord).
          Accordingly, Sections I.A., I.B., and I.C. of the Work Letter attached to the Third Amendment are hereby deleted in their entirety and the following substituted therefor.

       

      “I.           ARCHITECTURAL AND CONSTRUCTION PROCEDURES.

       

      	

            	A.	
              Tenant shall engage Design Blitz for the preparation of a detailed space plan for the Premises which includes interior partitions, ceilings, interior finishes, interior office doors,
                suite entrance, floor coverings, window coverings, lighting, electrical and telephone outlets, plumbing connections, heavy floor loads and other special requirements (“Preliminary Plan”).

                Upon completion of the Preliminary Plan, Landlord and Tenant shall approve an estimate of the cost to complete the Tenant Improvements in accordance with the Preliminary Plan (“Preliminary

                  Cost Estimate”), which Preliminary Cost Estimate will be based upon estimated costs provided by Landlord’s contractor. To the extent applicable, the Preliminary Plan shall include Landlord’s building standard tenant improvements,
                materials and specifications for the Project as set forth in Schedule I attached hereto (“Standard Improvements”), except for changes and
                additions specifically requested by Tenant and approved by Landlord in writing (any such addition or variation from the Standard Improvements shall be referred to herein as a “Non-Standard

                  Improvement”). In all events, Tenant shall approve in all respects a Preliminary Plan and a Preliminary Cost Estimate for the 43 Discovery Premises not later than May 31, 2018 (“Plan

                  Approval Date”), it being understood that Tenant’s failure to do so shall constitute a “Tenant Delay” (as defined below).

            

       

      
        1

        
          

      

      	

            	B.	
              Not later than July 31, 2018 (the “Working Drawings Delivery Date”), Tenant shall (i) cause its architect to prepare final
                construction drawings and specifications for the Tenant Improvements (“Working Drawings and Specifications”) and (ii) approve in writing the Working Drawings and Specifications and
                deliver same to Landlord for review and approval. It is understood that Tenant’s architect shall utilize Landlord’s mechanical, electrical, and plumbing engineer (i.e., TK1SC), and fire/life safety and fire sprinkler engineers for the
                Project. Tenant shall cause Landlord to be provided with CAD files of the final as-built construction drawings that are compatible with Landlord’s CAD/Revit standards, which standards shall be provided to Tenant or its architect upon
                request; should Tenant fail to deliver same by the substantial completion of the Tenant Improvement work, then Landlord may cause such CAD files to be prepared by its architect, the cost of which shall be funded by Tenant to Landlord within
                10 days after invoice therefor. The cost incurred by Tenant in preparing the Preliminary Plan and the Working Drawings and Specifications (but only to the extent the amount thereof is furnished to Landlord prior to the receipt of the
                contractors’ bids as described in Section I.C. below), together with the reasonable cost not to exceed $7,500.00 of Landlord’s architect to review same and the accompanying CAD files, shall be funded by Landlord from the “Landlord’s
                Contribution” set forth below upon delivery of invoices and payment authorization by Tenant. Tenant’s failure to deliver to Landlord the Tenant-approved Working Drawings and Specifications for the 43 Discovery Premises by the Working
                Drawings Delivery Date shall constitute a Tenant Delay for purposes hereof.

            

       

      	

            	C.	
              Upon approval of the Working Drawings and Specifications, Landlord shall submit the Working Drawings and Specifications for the Tenant Improvement Work to a competitive bidding
                process involving at least 3 licensed and reputable general contractors. If requested by Tenant, Landlord shall provide copies of the bid responses to Tenant. After adjustments for any inconsistent assumptions to reflect an “apples to
                apples” comparison, Landlord shall select the lowest qualified bidder for construction of the Tenant Improvements. In the event Landlord selects other than the lowest bidder, it shall do so based on commercially reasonable factors which it
                shall demonstrate to Tenant. Upon selection of the bidder, Landlord shall enter into a construction contract with the contractor so selected in the bid amount for construction of the Tenant Improvements (which bid amount shall serve as the
                “Final Cost Estimate”).”

            

       

      In addition, Section I.F of the Work Letter attached to the Third Amendment is hereby deleted in its entirety and the following substituted therefor:

       

      	

            	“F.	
              Notwithstanding any provision in the Lease to the contrary, and not by way of limitation of any other rights or remedies of Landlord, if Tenant fails to comply with any of the time
                periods specified in this Work Letter, fails otherwise to approve or reasonably disapprove any submittal within the time period specified herein for such response (or if no time period is so specified, within 5 business days following
                Tenant’s receipt thereof), fails to approve in writing both the Preliminary Plan and Preliminary Cost Estimate for the Tenant Improvements for the 43 Discovery Premises by the Plan Approval Date, fails to deliver to Landlord for Landlord’s
                approval the Working Drawings and Specifications by the Working Drawings Delivery Date, fails to timely deliver the Tenant’s Contribution as required hereunder, requests any Changes, furnishes inaccurate or erroneous specifications or other
                information, or otherwise delays in any manner the completion of the Tenant Improvements (including without limitation by specifying materials that are not readily available) or the issuance of an occupancy certificate (any of the foregoing
                being referred to in this Lease as a “Tenant Delay”), then Tenant shall bear any resulting additional construction cost or other expenses, and, to the extent the delay relates to
                the Tenant Improvements for the 43 Discovery Premises, the Commencement Date for the 43 Discovery Premises ,shall be deemed to have occurred for all purposes, including without limitation Tenant’s obligation to pay rent for the 43 Discovery
                Premises, as of the date Landlord reasonably determines that it would have been able to deliver the 43 Discovery Premises to Tenant but for the collective Tenant Delays. Should Landlord determine that the Commencement Date for the 43
                Discovery Premises should be advanced in accordance with the foregoing, it shall so notify Tenant in writing. Landlord’s determination shall be conclusive unless Tenant notifies Landlord in writing, within 5 business days thereafter of
                Tenant’s election to contest same pursuant to Section 14.7 of the Lease. Pending the outcome of such proceedings, Tenant shall make timely payment of all rent due under this Lease based upon the Commencement Date for the 43 Discovery
                Premises set forth in the aforesaid notice from Landlord.”

            

       

      
        2

        
          

      

      Further in addition, the last sentence of Section II.D of the Work Letter attached to the Third Amendment is hereby deleted in its entirety and the
        following substituted therefor:

       

      “Unless expressly authorized in writing by Landlord, and except for (i) a fee to be paid to Tenant’s construction manager not to exceed 2% of the
        Completion Cost, and (ii) the fees to be paid to Tenant’s architect, the Completion Cost shall not include (and no portion of the Landlord’s Contribution shall be paid for) any costs incurred by Tenant, including without limitation, any costs for
        managers, advisors or consultants retained by Tenant in connection with the Tenant Improvements.”

       

      	IV.	
              GENERAL.

            

       

      A.         Effect
            of Amendment. The Lease shall remain in full force and effect and unmodified except to the extent that it is modified by this Amendment.

       

      B.          Entire
            Agreement. This Amendment embodies the entire understanding between Landlord and Tenant with respect to the modifications set forth in “Ill. MODIFICATIONS” above and can be changed only by a
          writing signed by Landlord and Tenant.

       

      C.          Defined

            Terms. All words commencing with initial capital letters in this Amendment and defined in the Lease shall have the same meaning in this Amendment as in the Lease, unless they are otherwise defined in this Amendment.

       

      D.         Corporate

            and Partnership Authority. If Tenant is a corporation or partnership, or is comprised of either or both of them, each individual executing this Amendment for the corporation or partnership represents that he or she is duly authorized to
          execute and deliver this Amendment on behalf of the corporation or partnership and that this Amendment is binding upon the corporation or partnership in accordance with its terms.

       

      E.          Counterparts•

            Digital Signatures. If this Amendment is executed in counterparts, each is hereby declared to be an original; all, however, shall constitute but one and the same amendment. In any action or proceeding, any photographic, photostatic, or
          other copy of this Amendment may be introduced into evidence without foundation. The parties agree to accept a digital image (including but not limited to an image in the form of a PDF, JPEG, GIF file, or other e-signature) of this Amendment, if
          applicable, reflecting the execution of one or both of the parties, as a true and correct original.

       

      F.          California

            Certified Access Specialist Inspection. Pursuant to California Civil Code § 1938, Landlord hereby states that the Premises have not undergone inspection by a Certified Access Specialist (CASp) (defined in California Civil Code §
          55.52(a)(3)) Pursuant to Section 1938 of the California Civil Code, Landlord hereby provides the following notification to Tenant: “A Certified Access Specialist (CASp) can inspect the subject premises and determine whether the subject premises
          comply with all of the applicable construction-related accessibility standards under state law. Although state law does not require a CASp inspection of the subject premises, the commercial property owner or lessor may not prohibit the lessee or
          tenant from obtaining a CASp inspection of the subject premises for the occupancy or potential occupancy of the lessee or tenant, if requested by the lessee or tenant. The parties shall mutually agree on the arrangements for the time and manner
          of the CASp inspection, the payment of the fee for the CASp inspection, and the cost of making any repairs necessary to correct violations of construction related accessibility standards within the premises.” If Tenant requests to perform a CASp
          inspection of the Premises, Tenant shall, at its cost, retain a CASp approved by Landlord (provided that Landlord may designate the CASp, at Landlord’s option) to perform the inspection of the Premises at a time agreed upon by the parties. Tenant
          shall provide Landlord with a copy of any report or certificate issued by the CASp (the “CASp Report”) and Tenant shall, at its cost, promptly complete any modifications necessary to
          correct violations of construction related accessibility standards identified in the CASp Report, notwithstanding anything to the contrary in this Lease. Tenant agrees to keep the information in the CASp Report confidential except as necessary
          for the Tenant to complete such modifications.

       

      
        3

        
          

      

      	V.	
              EXECUTION.

            

       

      Landlord and Tenant executed this Amendment on the date as set forth in “I. PARTIES AND DATE.” above.

       

      

      
        
          	
                  
                    LANDLORD:

                  

                	 	
                  TENANT:

                
	 	 	 
	
                  
                    DISCOVERY BUSINESS CENTER LLC, a Delaware limited liability company

                  

                	 	
                  
                    GHOST MANAGEMENT GROUP, LLC, a Delaware limited liability company

                  

                
	 	 	

                
	
                  By:

                	
                  /s/ Steven M. Case

                	 	 	
                  By:

                	
                  
                    
                      /s/ Chris Beals

                    

                  

                	 

          	
                  
                    Name: Steven M. Case

                  

                	 	
                  Name: Chris Beals

                
	
                  Title: EVP Office Properties 

                	

                	
                  Title: President

                

           

          

          	By: 

                	
                  
                    /s/ Holly McManus

                    

                  

                	 	 	
                  By:

                	
                  /s/ Doug Francis

                  

                	 
	
                  Name: Holly McManus

                	 	
                  Name: Doug Francis

                
	
                  Title:   VP, Operations Office Properties

                	 	
                  Title:   CEO

                

           

          

           

           4Exhibit 10.17

    

    

    

    CONFIDENTIAL

  

  

  

  
    STRATEGIC ADVISOR AGREEMENT

     

    THIS STRATEGIC ADVISOR AGREEMENT (“Agreement”) is made and entered into between Ghost Management Group, LLC, a
      Delaware limited liability company (the “Company”), on the one hand, and Steven Jung, an individual (“Employee”), on the other
      hand.  Each of Company and Employee may be referred to individually as a “Party” and collectively as the “Parties.”

     

    RECITALS

     

    	

          	A.	
            Employee is an at-will employee of the Company;

          

     

    	

          	B.	
            As part of this Agreement, Employee and Company have agreed that June 30, 2021 will be Employee’s last day of active employment in his current role as President and Chief Operating Officer of the Company, WM
              Holding Company, LLC, and WM Technology, Inc. and he will remain in a paid employee advisory role from July 1, 2021 through July 6, 2022 (the “Advisory Services Period”).

          

     

    	

          	C.	
            The Company and Employee wish to effectuate a release of any and all claims that Employee holds against the Company and to resolve all controversies and disputes as hereinafter set forth.

          

     

    NOW, THEREFORE, in consideration of the Recitals, covenants and representations contained in this Agreement, and for other good and valuable consideration, the receipt and
      sufficiency of which is acknowledged, the Parties agree as follows:

     

    1.            Advisory Services Period & Termination of Employment.

     

    (a)         Advisory Services Period: Beginning on the first day of the Advisory Services
        Period and extending through last day of the Advisory Services Period (the “Services Completion Date”), Employee will be relieved of all of his responsibilities and duties except that he
        will continue to provide advisory services as an employee to the Company as requested in writing by the Company’s CEO. The Parties acknowledge and agree that during the Advisory Services Period, Employee is free to take on additional outside work
        or employment, including in a project, consulting or full-time role; provided, that any outside work is accepted and provided (x) in Employee’s individual capacity and not as a representative of the
        Company, and (y) subject to the Company’s Confidential Information, Non-Solicitation and Inventions Assignment Agreement signed by Employee as a condition of his employment with the Company, as well as Employee’s obligations pursuant to this
        Agreement, including the confidentiality obligations in Section 9. As consideration for the advisory services provided during the Advisory Services Period and the Release of Claims in Section 3, and subject to the terms of this Agreement, (i)
        Employee will continue to be paid his regular salary on the Company’s normal payroll dates during the Advisory Services Period ”)(less standard deductions and withholdings)(the “Advisory Services
          Compensation”), (ii) the Class P Units of WM Holding Company, LLC, a Delaware limited liability company and parent company of the Company (“WM Holding”) held by Employee pursuant
        to the Equity Award Agreements (defined below) will continue to vest on their normal schedule during the Advisory Services Period (the “Advisory Services Units”), and (iii) his health
        insurance and 401k benefits will be maintained by the Company (the “Insurance Benefit”). Except as stated in this Section 1(a), Employee will not be eligible for any other wages, payments,
        bonuses, incentives, equity vesting, or benefits (including sick leave or accrual of vacation time) during the Advisory Services Period. In the event Employee breaches any provision of this Agreement, the Company will immediately cease providing
        the payments and benefits stated in this Section 1(a), and process Employee’s separation of employment and Employee will not be entitled to any further payments or benefits under this Agreement. Employee acknowledges and agrees that Employee will
        promptly notify the Company if he acquires alternative health insurance coverage at any point during the Advisory Services Period, in which case, the Company will cease providing health insurance benefits to Employee. Notwithstanding anything to
        the contrary contained herein, (i) the Advisory Services Compensation will not exceed an aggregate amount of $609,863 and (ii) a maximum of 278,897 Class P Units will vest as part of the Advisory Services Units.

     

      

    
      
        

    

    
    (b)        Termination of Employment: Employee’s employment with the Company in any and all
        capacities will be terminated effective as of the Services Completion Date. Employee acknowledges that Employee has received all wages, benefits and other amounts due up to and including the first day of the Advisory Services Period, including
        without limitation any and all wages, compensation, vacation, sick leave, overtime, commissions, options, bonuses, profit sharing, benefits, insurance, or any other form of payment.  Employee acknowledges that payment any portion of Employee’s
        wages, including vacation pay, was not conditioned on Employee signing this Agreement.

     

    (c)        Alternative Insurance Benefit: If the Company determines at any point during
        the Advisory Services Period that Employee may not remain covered by the Company’s employer-provided health insurance policies then Employee will no longer be entitled to participate in any Company healthcare benefit plan, and the Company shall
        provide Employee notice regarding Employee’s right to continue Employee’s healthcare coverage pursuant to COBRA. If and for so long as Employee enrolls in COBRA, the Company will pay directly Employee’s COBRA premium for health insurance for the
        remainder of the Advisory Services Period (the “Alternative Insurance Benefit”). Company will not enroll Employee in COBRA and Employee will be fully responsible for completing any and all
        paperwork necessary for COBRA enrollment. Employee acknowledges and agrees that Employee will promptly notify the Company if he acquires alternative health insurance coverage at any point during the Advisory Services Period, in which case, the
        Company will cease providing the Alternative Insurance Benefit to Employee.

     

    2.         Return of All Company Materials.  Employee hereby certifies that
        Employee has returned to Company all Company records, documents, electronically stored information, and tangible embodiments of such, prepared by Employee or coming into Employee’s possession by virtue of Employee’s employment with
        Company.  To the extent Employee is unable to return such materials that are in a digital form, Employee shall remove all copies of such digital material and certify the destruction or deletion of such digital copies.  Employee further certifies
        that Employee has returned to Company all property of Company, including but not limited to pagers, keys, key cards, cellular phones, credit cards, personal and laptop computers, and other electronic equipment.  Employee agrees that should Employee
        at any future time discover additional items of property belonging to Company, Employee will promptly return such property to Company.

     

    3.          General Release.  Except as to such rights or claims as may be created by this Agreement, Employee and Employee’s respective heirs, administrators, successors in interest, assigns and agents, hereby release and forever discharge the Company and its
        current and former officers, directors, shareholders, employees, representatives, attorneys, agents, members, trustees, administrators, owners, partners, insurers, fiduciaries, subsidiaries, parent companies, affiliates, related entities, assigns,
        predecessors and successors in interest,  jointly and severally (referred to collectively hereafter as the “Releasees”),

        from any and all claims, demands, liabilities, suits, causes of action, charges, complaints, obligations, costs, losses, damages, injuries, penalties, interest, attorneys’ fees, and other legal responsibilities, of any form whatsoever, whether
        known or unknown, unforeseen, unanticipated, unsuspected or latent (referred to collectively hereafter as “Claim” or “Claims”), which Employee has at any time owned or held up to and including the date Employee signs this Agreement (including during
        the Revocation Period (as defined below)), including, and without limiting the generality of the foregoing, any and all Claims arising out of, connected with, or relating to:  (1) Employee’s employment with the Company or the termination of that
        employment; (2) any act or omission by or on the part of any of the Releasees; (3) any alleged violation of California Labor Code, applicable California Wage Order, Fair Labor Standards Act or the Consolidated Omnibus Budget Reconciliation Act
        (COBRA), as amended; (4) any Claim arising under the Labor Code Private Attorneys General Act (PAGA), Labor Code §§ 2699, et seq.; (5) any  federal, state or local law regulating compensation, salaries, wages, meal periods, rest periods, itemized
        wage statements, pay stubs or payroll records, hours, bonuses, commissions, overtime, benefits, monies, pay, allowances, benefits, sick pay, severance pay, retention pay or benefits, paid leave benefits, vacation pay, penalties, interest or
        damages; (6) any Claim for violation of any federal, state or local law or regulation prohibiting discrimination, harassment or retaliation of any kind; (7) breach of any express or implied employment contract or agreement, wrongful discharge,
        breach of the implied covenant of good faith and fair dealing, intentional or negligent infliction of emotional distress, fraud, misrepresentation, defamation, trespass, conversion, interference with prospective economic advantage, and invasion of
        privacy; and (8) any Claim for attorneys’ fees, costs or expenses.  The foregoing general release does not apply to any Claim that cannot be released as a matter of law.  Nothing in this Agreement prohibits or prevents Employee from filing a charge
        with or participating, testifying, or assisting in any investigation, hearing, or other proceeding before any federal, state, or local government agency.  However, to the maximum extent permitted by law, Employee agrees that if such an
        administrative claim is made, Employee shall not be entitled to recover any individual monetary relief or other individual remedies.

     

      

    
      2

      
        

    

    Employee agrees that the release provided by this Agreement applies to any Claims brought by any person or agency on behalf of Employee or any class action, representative action
      or collective action pursuant to which Employee may have any right or benefit.  Employee agrees not to participate in any class action, representative action or collective action that may include or encompass any of the Claims released by this
      Agreement.  With respect to any Claims released by this Agreement, Employee further agrees not to accept any recovery or benefit that may be obtained on Employee’s behalf by any other person or agency or in any class action, representative action or
      collective action, and does hereby assign any such recovery or benefit to the Company.  In addition, Employee agrees that in the event Employee receives any notice from any claims administrator, attorney, law firm or other person purporting to
      represent Employee or any class or group which includes Employee, and such notice references any lawsuit or threatened lawsuit against the Company or any of the Releasees that encompasses any of the Claims released by this Agreement, Employee will
      promptly notify such claims administrator, attorney, law firm, or other person that Employee does not wish to participate in and specifically “opts out” of any class action, representative action or collective action against the Company or any of the
      Releasees.  Finally, by signing this Agreement, Employee acknowledges and agrees that Employee is not an “aggrieved employee,” as that term is defined in the Labor Code Private Attorneys General Act (PAGA), with respect to any Claims released by this
      Agreement.

    

    

    Notwithstanding anything to the contrary herein, the foregoing release shall not cover, and Employee does not release, any rights of Employee under this Agreement or the Equity
      Award Agreements, dated as of June 26, 2017, May 10, 2018 and May 7, 2020, respectively (collectively, as the same may be amended and/or restated from time to time, the “Equity Award Agreements”),

      between Employee and WM Holding, or any rights of Employee as a holder of Class P Units of WM Holding under the Certificate of Formation or the Fourth Amended and Restated Operating Agreement of WM Holding, dated as of June 16, 2021 (as the same may
      be amended and/or restated from time to time, the “Amended and Restated LLC Agreement”). Employee acknowledges and agrees that Employee will own an aggregate total of 1,035,514 vested Class
      P Units of WM Holding as of the first day of the Advisory Services Period, and, if Employee accepts and executes this Agreement, WM Holding will permit continued vesting of the Advisory Services Units during the Advisory Services Period, so that
      Employee will have vested in an aggregate total of 1,314,411 vested Class P Units as of the Services Completion Date, all 1,314,411 of which shall be retained by Employee following the Services Completion Date pursuant and subject to the Equity Award
      Agreements, the Amended and Restated LLC Agreement and the WM Holding Third Amended and Restated Equity Incentive Plan, dated as of August 15, 2018 as may be amended, restated, supplemented, or otherwise modified from time to time (the “Plan”). Except for the Advisory Services Units, Employee acknowledges that Employee forfeits all Class P Units granted to Employee under the Equity Award Agreement and which are unvested as of
      the Services Completion Date pursuant to the terms of the Equity Award Agreement, the Amended and Restated LLC Agreement and the Plan. Except as set forth in this paragraph, Employee acknowledges that Employee has no right, title or interest to any
      other equity, options or equivalents of Company or its affiliates.

     

    

    
      3

      
        

    

    4.          Release of All Unknown Claims.  The general
        release above is intended to be a full and final release covering all unsuspected, unknown, undisclosed and unanticipated Claims which may have arisen, or may arise, from any act or omission up to and including the date Employee signs this
        Agreement, including during the Revocation Period, and which arise out of or are related,
        directly or indirectly, to the dealings between the Parties or any matters described in this Agreement.  Employee, and on behalf of anyone or any entity claiming through Employee, each waive any and all rights or benefits which they may now have,
        or in the future may have, under the terms of Section 1542 of the California Civil Code, which provides as follows:

     

    A GENERAL RELEASE DOES NOT EXTEND TO CLAIMS THAT THE CREDITOR OR RELEASING PARTY DOES NOT KNOW OR SUSPECT TO EXIST IN HIS OR HER FAVOR AT THE TIME OF EXECUTING THE RELEASE AND
      THAT, IF KNOWN BY HIM OR HER, WOULD HAVE MATERIALLY AFFECTED HIS OR HER SETTLEMENT WITH THE DEBTOR OR RELEASED PARTY.

     

    Notwithstanding the provision of Section 1542, and for the purpose of implementing a full and complete release and discharge, Employee expressly acknowledges that the general
      release above is intended to include and does include in its effect, without limitation, all Claims which Employee does not know or suspect to exist in Employee’s favor against any of the Releasees up to and including the date Employee signs this
      Agreement and that the release in this Agreement expressly contemplates the extinguishment of all such Claims.

     

    5.          No Admissions.  Neither this Agreement nor the furnishing of the
        consideration for this Agreement shall be deemed or construed as an admission of liability or wrongdoing on the part of either Party, nor shall they be admissible as evidence in any proceeding other than for the enforcement of this Agreement.

     

    6.          Covenant Not to Sue.  Employee has not and will not directly or
        indirectly institute any legal action against the Releasees based upon, arising out of, or relating to any Claims released herein.  Employee has not and will not directly or indirectly encourage and/or solicit any third party to institute any legal
        action against the Releasees.

     

      

    
      4

      
        

    

    7.           Intellectual Property of the Company.  As additional consideration
        for the execution and delivery of this Agreement and only to the extent not already obligated to do so with respect to the Company and without limitation to any other agreement Employee has with the Company with respect to the following matters:

     

      

    (a)       Employee agrees to disclose in writing to the Company all source code, passwords, inventions, products, designs, drawings, notes, information,
      documentation, improvements, works of authorship, processes, techniques, know-how, technical specifications, hardware, computer programs, databases, user interfaces, encoding techniques, and other materials or innovations of any kind that Employee
      has made, conceived, developed or reduced to practice, alone or jointly with others, in connection with Employee’s term of service to the Company prior to the Services Completion Date or that resulted from or that related thereto, whether or not they
      are eligible for patent, copyright, mask work, trade secret, trademark or other legal protection (“Innovations”).

     

    (b)         Employee and the Company agree that, to the fullest extent legally possible, all Innovations (as defined in Section 7(a)) will be “works for hire”
      as that term is defined in Section 101 of the 1976 Copyright Act, and shall be owned exclusively by the Company.  Employee agrees that, regardless of whether the Innovations are legally works for hire, all Innovations will be the sole and exclusive
      property of the Company.  Employee hereby irrevocably transfers and assigns to the Company, and agrees to irrevocably transfer and assign to the Company, all of Employee’s right, title and interest in and to the Innovations, including all worldwide
      patent rights (including patent applications and disclosures), copyright rights, mask work rights, trade secret rights, know-how, and any and all other intellectual property or proprietary rights therein (collectively, “Intellectual Property Rights”).  At the Company’s request and expense, during and after the term of this Agreement, Employee will assist and cooperate with the Company in all respects and will execute documents
      (including, without limitation, assignments as to any Intellectual Property Rights which become the property of the Company pursuant to this Section 7) and, subject to the reasonable availability of Employee, will give testimony and take such further
      acts reasonably requested by the Company to enable the Company to acquire, transfer, maintain, perfect and enforce its Intellectual Property Rights and other legal protections for the Innovations.  Employee hereby appoints the Company as
      attorney-in-fact to execute documents on behalf of Employee for this limited purpose.

     

    (c)         Employee hereby irrevocably transfers and assigns to the Company, and agrees to irrevocably transfer and assign to the Company, and waives and
      agrees never to assert, any and all Moral Rights (as defined below) that Employee may have in or with respect to any Innovation, during and after the term of this Agreement.  “Moral Rights”
      mean any rights to claim authorship of an Innovation (as defined in Section 7(a)), to object to or prevent the modification or destruction of any Innovation, to withdraw from circulation or control the publication or distribution of any Innovation,
      and any similar right, existing under judicial or statutory law of any country in the world, or under any treaty, regardless of whether or not such right is called or generally referred to as a “moral right.”

     

    (d)         To the extent that Employee owns or controls any patent rights, copyright rights, mask work rights, trade secret rights, or any other intellectual
      property or proprietary rights that block or interfere with the rights assigned to the Company under this Agreement (collectively, “Related Rights”), Employee hereby grants or will cause to
      be granted to the Company a non-exclusive, royalty-free, irrevocable, worldwide license to make, have made, use, offer to sell, sell, import, copy, modify, create derivative works based upon, distribute, sublicense, display, perform and transmit any
      products, software, hardware, methods or materials of any kind that are covered by such Related Rights, to the extent necessary to enable the Company to exercise all of the rights assigned to the Company under this Agreement.

     

    

    
      5

      
        

    

    8.          Cooperation.  Employee agrees that, during the period, if any, between
        the Effective Date and the Services Completion Date, he will act in support of the Company and its business interests and assist with the smooth transition of his responsibilities. Employee agrees to cooperate with the Company and make themselves
        generally available in connection with disputes between the Company and third parties.  This cooperation may include, but is not limited to, conferring with and assisting the Company in preparatory work in litigation matters, providing factual
        information to the Company, and giving depositions and testimony in judicial and administrative proceedings.  Employee agrees that Employee will not be paid by the Company for Employee’s cooperation.  Employee further agrees to make themselves
        available on a reasonable basis with respect to any outstanding legal, business or strategic matters as necessary following the Effective Date.

     

    9.          Confidentiality. Except as otherwise prohibited by law, Employee
        agrees that neither Employee nor any of Employee’s agents or representatives will disclose, disseminate and/or publicize, or cause or permit to be disclosed, disseminated or publicized, any attorney client privileged information, attorney work
        product, confidential information or trade secrets of the Company, or any claims or allegations which Employee could have made or asserted against the Company, to any person, corporation, association or governmental agency or other entity except: 
        (a) to the extent necessary to report income to appropriate taxing authorities; (b) to members of Employee’s immediate family; (c) in response to an order of a court of competent jurisdiction or subpoena issued under the authority thereof; or (d)
        in response to any inquiry or subpoena issued by a state or federal governmental agency; provided, however, that notice of receipt of such judicial order or subpoena shall be immediately communicated by Employee to the Company telephonically, and
        confirmed immediately thereafter in writing, so that the Company will have the opportunity to assert what rights it has to non-disclosure prior to Employee’s response to the order, inquiry or subpoena. Should Employee disclose to Employee’s
        immediate family members any of the terms this Agreement, Employee will advise them that they are under the same obligation of confidentiality as described in this Section.  Employee also agrees not to disclose any confidential or proprietary
        information pertaining to the business of the Company and/or its customers.  For the avoidance of doubt, the confidentiality obligations of this Section shall extend to any information Employee has with respect to the businesses or activities of
        the Company Entities and any prospective opportunities which such equity holders have discussed or considered pursuing as well as any information received from any actual or potential customers of the Company.

     

    Any violation of the confidentiality provision contained in this Agreement by Employee shall be considered a material breach of this Agreement.

    

    

    10.       Non-Disparagement.  Employee agrees that on a permanent basis Employee
        will not make any negative, critical, disparaging, detrimental or derogatory comments (whether verbally or in writing) to anyone, including any employee or third party concerning the Company, or any of its current and former officers, directors,
        shareholders, employees, representatives, attorneys and agents, as well as its predecessors, parents, subsidiaries, affiliates, divisions, and successors-in-interest.  With respect to the Company, the foregoing includes, but is not limited to, the
        Company’s services, products, processes, policies, practices, standards of business conduct, and areas or techniques of research and/or development and the actual or planned activities, the plans, processes or business practices of the equity
        holders of the Company or any Company Entities.  The first sentence of this Section 10 shall not apply to any communication or disclosure to the extent required to institute any proceedings to enforce the terms of this Agreement or as otherwise
        expressly authorized and required by law or lawful process.  Company will respond to any inquiries about Employee’s employment by providing only Employee’s dates of employment, job title, and, if authorized by Employee in writing, Employee’s last
        rate of pay.  Employee will direct all such inquiries only to Company’s People Operations Department. Employee agrees that Employee’s failure to comply with this non-disparagement provision shall be deemed a material breach of this Agreement and
        shall entitle Company to immediately (a) stop providing the Advisory Services Period benefits set forth in Sections 1(a) and 1(c) including the Advisory Services Compensation, Insurance Benefit, and, if applicable, the Alternative Insurance
        Benefit, (b) seek recoupment of any amounts already paid to Employee, and (c) cancel the vesting of the Advisory Services Units, in addition to recovering damages for breach.

     

      

    
      6

      
        

    

    11.        Right to an Attorney; Time to Consider. This Agreement constitutes a
        knowing and voluntary waiver of any and all rights or claims that Employee has or may have under the federal Age Discrimination in Employment Act (ADEA), as amended by the Older Workers’ Benefit Protection Act of 1990, 29 U.S.C. §§ 621 et seq.  This Section and this Agreement are written in a manner calculated to be understood by Employee. Employee acknowledges and agrees that Employee has had twenty-one (21) days to consider this Agreement
        and to consult with counsel, and the Company has advised Employee of Employee’s right to do so.  To the extent that Employee has taken less than twenty-one (21) days to consider this Agreement, Employee acknowledges that Employee has had sufficient
        time to consider the Agreement and to consult with counsel and that Employee did not desire additional time.  The terms of this Agreement will not become enforceable for seven (7) calendar days following the date of execution of this Agreement (the
        “Revocation Period”), during which time Employee may revoke this Agreement by notifying the undersigned representative of the Company in writing by registered letter. In the event of any
        such revocation, the Employee acknowledges and agrees that the Equity Award Agreements shall be deemed revoked as well by the Employee.

     

    12.         Cancellation and Repayment of Advisory Services Benefits.  In the
        event of breach of this Agreement by Employee, including, but not limited to, the confidentiality and non-disparagement provisions during the period that begins on the Effective Date, then in addition to any remedies available to the Company at law
        or equity, the Company shall be immediately entitled to terminate Employee’s employment (if during the Advisory Services Period) and stop all payments and benefits under this Agreement. This means that Company may (i) withhold any and all payments
        of Insurance Benefits or Alternative Insurance Benefits to Employee or owed to cover COBRA premiums pursuant to Section 1 of this Agreement, (ii) cancel the vesting of the Advisory Services Units, and (iii) cancel payments of the Advisory Services
        Compensation. Employee agrees to promptly return to Company the full monetary value of the Advisory Services Compensation, Insurance Benefits and Alternative Insurance Benefits that was received by Employee and to indemnify and hold harmless the
        Releasees for and against any and all costs, losses, or liability whatsoever, including reasonable attorneys’ fees, caused by Employee’s breach of this Agreement.  Furthermore, Employee agrees that the return or obligation to return the amount of
        the Advisory Services Compensation, Insurance Benefit, and Alternative Insurance Benefits to the Company and the cancellation of the vesting of the Advisory Services Units will not abrogate or affect in any way Employee’s full release of any and
        all Claims against the Releasees.  Employee acknowledges and agrees that the provisions contained in this Section 12 are reasonable and necessary for the protection of the Company’s legitimate business interests, and further agrees not to challenge
        the reasonableness of such restrictions.

     

    13.       Section 409A of the Code.  While the tax treatment of the payments
        provided under this Agreement is not warranted or guaranteed, it is intended that such payments shall either be exempt from, or comply with, the requirements of Section 409A of the Internal Revenue Code of 1986, as amended.  This Agreement shall be
        construed, administered and governed in a manner that effects such intent.

     

    14.        Waiver and Modification.  The failure to enforce any provision of this
        Agreement shall not be construed to be a waiver of such provision or to affect either the validity of this Agreement or the right of any Party to enforce the Agreement.  This Agreement may be modified or amended only by a written agreement executed
        by Employee and the Company.

     

      

    
      7

      
        

    

    15.        Severability and Savings Provision.  In the event that any provision
        of this Agreement should be held to be void, voidable, or unenforceable, the remaining portions hereof shall remain in full force and effect.  Additionally, in the event that any portion of this Agreement is deemed void or unenforceable, the
        Parties will be excused from performing that portion of the Agreement.

     

    16.        Entire Agreement.  This Agreement constitutes the entire agreement
        between Employee and the Company and supersedes and cancels all prior agreements, oral or written, if any, between Employee and the Company, except that this Agreement does not alter, modify, or impact any pre-existing confidentiality provisions
        and restrictive covenants between the Parties, nor does it affect Employee’s obligation to comply with those provisions and covenants.

     

    17.        Arbitration.  The Parties hereby agree to submit any claim or dispute
        arising out of the terms of this Agreement to private and confidential arbitration by a single neutral arbitrator through Judicial Arbitration and Mediation Services, Inc. (“JAMS”).  This
        arbitration provision covers all claims that Employee may have against Company, or that Company may have against Employee.  The JAMS Streamlined Arbitration Rules & Procedures in effect at the time the claim or dispute is arbitrated will govern
        the procedure for the arbitration proceedings between the Parties.  The arbitration shall take place in Los Angeles, California.  The arbitrator in this matter shall not have the power to modify any of the provisions of this Agreement.  The
        decision of the arbitrator shall be final and binding on all Parties to this Agreement, and judgment thereon may be entered in any court having jurisdiction.  Company shall initially advance the arbitrator’s fee and all costs of services provided
        by the arbitrator and arbitration organization.  However, the arbitrator’s fee and all costs of services provided by the arbitration organization, as well as reasonable attorneys’ fees and recoverable costs, shall be paid as the arbitrator or court
        awards in accordance with applicable law.  The Parties hereby waive any right to a jury trial on any dispute or claim covered by this Agreement.

     

    18.        Governing Law.  This Agreement shall be construed in accordance with,
        and be governed by the laws of the State of California, both procedural and substantive.

     

    19.       Review Period and Effective Date. Employee has until June 28, 2021 to
        review, sign and return this Agreement to the Company. This Agreement is effective as of the first day of the Advisory Services Period (the “Effective Date”).

     

    
      8

      
        

    

    PLEASE READ CAREFULLY.  THIS AGREEMENT CONTAINS A RELEASE OF ALL KNOWN AND UNKNOWN CLAIMS.  THE UNDERSIGNED AGREE TO THE TERMS OF THIS AGREEMENT AND
      VOLUNTARILY ENTER INTO IT WITH THE INTENT TO BE BOUND THEREBY.

    

    

    The undersigned have carefully read this Agreement and understand that it contains a release of known and unknown claims.  The undersigned acknowledge and agree to all of the
      terms and conditions of this Agreement.  The undersigned further acknowledge that they are entering into this Agreement voluntarily as of the Effective Date with a full understanding of its terms.

    

    

    	 	
            /s/ Steven Jung

          	 
	 	
            Steven Jung

          
	 	 
	 	
            Dated:

          	June 21, 2021

          	 
	 	 
	 	
            Ghost Management Group, LLC

          
	 	 
	 	
            By:

          	/s/ Christopher Beals	 
	 	

          	Christopher Beals
	 	

          	Its Authorized Signatory
	 	 
	 	
            Dated:

            

          	June 21, 2021	 

     

    

     

    

    
      9

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00329-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00329-of-00352.parquet"}]]