Document:

<Page>

                                                                     Exhibit 4.2

                          REGISTRATION RIGHTS AGREEMENT

                                  by and among

                        PREMIER ENTERTAINMENT BILOXI LLC
                     (D/B/A HARD ROCK HOTEL & CASINO BILOXI)
                          PREMIER FINANCE BILOXI CORP.

                                       and

                         BANC OF AMERICA SECURITIES LLC
                          CITIGROUP GLOBAL MARKETS INC.
               MERRILL LYNCH, PIERCE, FENNER & SMITH INCORPORATED

                          Dated as of January 23, 2004

<Page>

                          REGISTRATION RIGHTS AGREEMENT

     This Registration Rights Agreement (this "AGREEMENT") is made and entered
into as of January 23, 2004, by and among Premier Entertainment Biloxi LLC
(d/b/a Hard Rock Hotel & Casino Biloxi), a Delaware limited liability company
("PREMIER ENTERTAINMENT"), Premier Finance Corp., a Delaware corporation and a
wholly-owned subsidiary of Premier Entertainment ("PREMIER FINANCE" and,
together with Premier Entertainment, the "ISSUERS"), and Banc of America
Securities LLC, Citigroup Global Markets Inc. and Merrill Lynch, Pierce, Fenner
& Smith Incorporated (each an "INITIAL PURCHASER" and, collectively, the
"INITIAL PURCHASERS"), each of whom has agreed to purchase the Issuers' 10 3/4%
First Mortgage Notes due 2012 (the "INITIAL NOTES") pursuant to the Purchase
Agreement (as defined below) for so long as such securities constitute Transfer
Restricted Securities (as defined below).

     This Agreement is made pursuant to the Purchase Agreement, dated as of
January 15, 2004 (the "PURCHASE AGREEMENT"), by and among the Issuers and the
Initial Purchasers (i) for the benefit of each Initial Purchaser and (ii) for
the benefit of the holders from time to time of the Notes (as defined below)
(including each Initial Purchaser). In order to induce the Initial Purchasers to
purchase the Initial Notes, the Issuers have agreed to provide the registration
rights set forth in this Agreement. The execution and delivery of this Agreement
is a condition to the obligations of the Initial Purchasers set forth in Section
5(l) of the Purchase Agreement.

     The parties hereby agree as follows:

     SECTION 1. DEFINITIONS. As used in this Agreement, the following
capitalized terms shall have the following meanings:

     BROKER-DEALER: Any broker or dealer registered under the Exchange Act.

     CLOSING DATE:  The date of this Agreement.

     COMMISSION:  The Securities and Exchange Commission.

     CONSUMMATE: A Registered Exchange Offer shall be deemed "Consummated" for
purposes of this Agreement upon the occurrence of each of the following: (i) the
filing and effectiveness under the Securities Act of the Exchange Offer
Registration Statement relating to the Exchange Notes to be issued in the
Exchange Offer, (ii) the maintenance of such Registration Statement continuously
effective and the keeping of the Exchange Offer open for a period not less than
the minimum period required pursuant to Section 3(b) hereof and (iii) the
delivery by the Issuers to the Registrar (as defined in the Indenture) under the
Indenture of Exchange Notes in the same aggregate principal amount as the
aggregate principal amount of Initial Notes that were tendered by Holders
thereof pursuant to the Exchange Offer.

     EFFECTIVENESS TARGET DATE:  As defined in Section 5.

     EXCHANGE ACT:  The Securities Exchange Act of 1934, as amended.

<Page>

     EXCHANGE NOTES: The 10 3/4% First Mortgage Notes due 2012, of the same
series under the Indenture as the Initial Notes, to be issued to Holders in
exchange for Transfer Restricted Securities pursuant to this Agreement.

     EXCHANGE OFFER: The registration by the Issuers under the Securities Act of
the Exchange Notes pursuant to an Exchange Offer Registration Statement pursuant
to which the Issuers offer the Holders of all outstanding Transfer Restricted
Securities the opportunity to exchange all such outstanding Transfer Restricted
Securities held by such Holders for Exchange Notes in an aggregate principal
amount equal to the aggregate principal amount of the Transfer Restricted
Securities tendered in such exchange offer by such Holders.

     EXCHANGE OFFER REGISTRATION STATEMENT: The Registration Statement relating
to the Exchange Offer, including the related Prospectus.

     EXEMPT RESALES: The transactions in which the Initial Purchasers propose to
sell the Initial Notes to certain "qualified institutional buyers," as such term
is defined in Rule 144A under the Securities Act and to certain non-U.S. Persons
(as defined in Rule 902(k) of Regulation S under the Securities Act).

     HOLDERS:  As defined in Section 2(b) hereof.

     INDEMNIFIED HOLDER:  As defined in Section 8(a) hereof.

     INDENTURE: The Indenture, dated as of January 23, 2004, among the Issuers
and U.S. Bank National Association, as trustee (the "TRUSTEE"), pursuant to
which the Notes are to be issued, as such Indenture is amended or supplemented
from time to time in accordance with the terms thereof.

     INITIAL PURCHASER:  As defined in the preamble hereto.

     INITIAL NOTES:  As defined in the preamble hereto.

     INITIAL PLACEMENT: The issuance and sale by the Issuers of the Initial
Notes to the Initial Purchasers pursuant to the Purchase Agreement.

     INTEREST PAYMENT DATE:  As defined in the Indenture and the Notes.

     LIQUIDATED DAMAGES:  As defined in Section 5 hereof.

     NASD:  National Association of Securities Dealers, Inc.

     NOTES:  The Initial Notes and the Exchange Notes.

     PERSON: An individual, partnership, corporation, limited liability company,
trust or unincorporated organization, or a government or agency or political
subdivision thereof.

                                        2
<Page>

     PROSPECTUS: The prospectus included in a Registration Statement, as amended
or supplemented by any prospectus supplement and by all other amendments
thereto, including post-effective amendments, and all material incorporated by
reference into such Prospectus.

     REGISTRATION DEFAULT:  As defined in Section 5 hereof.

     REGISTRATION STATEMENT: Any registration statement of the Issuers relating
to (a) an offering of Exchange Notes pursuant to an Exchange Offer or (b) the
registration for resale of Transfer Restricted Securities pursuant to the Shelf
Registration Statement, which is filed pursuant to the provisions of this
Agreement, in each case, including the Prospectus included therein, all
amendments and supplements thereto (including post-effective amendments) and all
exhibits and material incorporated by reference therein.

     SECURITIES ACT:  The Securities Act of 1933, as amended.

     SHELF FILING DEADLINE:  As defined in Section 4 hereof.

     SHELF REGISTRATION STATEMENT:  As defined in Section 4 hereof.

     TRUST INDENTURE ACT: The Trust Indenture Act of 1939 (15 U.S.C. Section
77aaa 77bbbb) as in effect on the date of the Indenture.

     TRANSFER RESTRICTED SECURITIES: Each Note, until the earliest to occur of
(a) the date on which such Note is exchanged in the Exchange Offer and entitled
to be resold to the public by the Holder thereof without complying with the
prospectus delivery requirements of the Securities Act, (b) the date on which
such Note has been effectively registered under the Securities Act and disposed
of in accordance with a Shelf Registration Statement and (c) the date on which
such Note is distributed to the public pursuant to Rule 144 under the Securities
Act or by a Broker-Dealer pursuant to the "Plan of Distribution" contemplated by
the Exchange Offer Registration Statement (including delivery of the Prospectus
contained therein).

     UNDERWRITTEN REGISTRATION OR UNDERWRITTEN OFFERING: A registration in which
securities of the Issuers are sold to an underwriter for reoffering to the
public.

     SECTION 2. SECURITIES SUBJECT TO THIS AGREEMENT.

     (a) TRANSFER RESTRICTED SECURITIES.  The securities entitled to the
benefits of this Agreement are the Transfer Restricted Securities.

     (b) HOLDERS OF TRANSFER RESTRICTED SECURITIES.  A Person is deemed to be a
holder of Transfer Restricted Securities (each, a "HOLDER") whenever such Person
owns Transfer Restricted Securities.

     SECTION 3. REGISTERED EXCHANGE OFFER.

     (a) Unless the Exchange Offer shall not be permissible under applicable
law or Commission interpretation or policy (after the procedures set forth in
Section 6(a) below have been complied with), the Issuers shall (i) use their
reasonable best efforts to cause to be filed

                                        3
<Page>

with the Commission as soon as practicable after the Closing Date, but in no
event later than 90 days after the Closing Date, an Exchange Offer Registration
Statement under the Securities Act, (ii) use their best efforts to cause such
Exchange Offer Registration Statement to become effective at the earliest
possible time, but in no event later than 210 days after the Closing Date, (iii)
in connection with the foregoing, file (A) all pre-effective amendments to such
Exchange Offer Registration Statement as may be necessary in order to cause such
Exchange Offer Registration Statement to become effective, (B) if applicable, a
post-effective amendment to such Exchange Offer Registration Statement pursuant
to Rule 430A under the Securities Act and (C) cause all necessary filings in
connection with the registration and qualification of the Exchange Notes to be
made under the Blue Sky laws of such jurisdictions as are necessary to permit
Consummation of the Exchange Offer, and (iv) upon the effectiveness of such
Exchange Offer Registration Statement, commence the Exchange Offer. The Exchange
Offer shall be on the appropriate form permitting registration of the Exchange
Notes to be offered in exchange for the Transfer Restricted Securities and to
permit resales of Notes held by Broker-Dealers as contemplated by Section 3(c)
below.

     (b) The Issuers shall cause the Exchange Offer Registration Statement to
be effective continuously and shall keep the Exchange Offer open for a period of
not less than the minimum period required under applicable federal and state
securities laws to Consummate the Exchange Offer; PROVIDED, HOWEVER, that in no
event shall such period be less than 30 days after the date notice of the
Exchange Offer is mailed to the Holders. The Issuers shall cause the Exchange
Offer to comply with all applicable federal and state securities laws. No
securities other than the Notes shall be included in the Exchange Offer
Registration Statement. The Issuers shall use their best efforts to cause the
Exchange Offer to be Consummated on the earliest practicable date after the
Exchange Offer Registration Statement has become effective, but in no event
later than 30 business days after the Exchange Offer Registration Statement was
declared effective.

     (c) The Issuers shall indicate in a "Plan of Distribution" section
contained in the Prospectus forming a part of the Exchange Offer Registration
Statement that any Broker-Dealer who holds Initial Notes that are Transfer
Restricted Securities and that were acquired for its own account as a result of
market-making activities or other trading activities (other than Transfer
Restricted Securities acquired directly from the Issuers), may exchange such
Initial Notes pursuant to the Exchange Offer; HOWEVER, such Broker-Dealer may be
deemed to be an "underwriter" within the meaning of the Securities Act and must,
therefore, deliver a prospectus meeting the requirements of the Securities Act
in connection with any resales of the Exchange Notes received by such
Broker-Dealer in the Exchange Offer, which prospectus delivery requirement may
be satisfied by the delivery by such Broker-Dealer of the Prospectus. Such "Plan
of Distribution" section shall also contain all other information with respect
to such resales by Broker-Dealers that the Commission may require in order to
permit such resales pursuant thereto, but such "Plan of Distribution" shall not
name any such Broker-Dealer or disclose the amount of Notes held by any such
Broker-Dealer except to the extent required by the Commission as a result of a
change in policy after the date of this Agreement.

     The Issuers shall use their best efforts to keep the Exchange Offer
Registration Statement continuously effective, supplemented and amended as
required by the provisions of Section 6(c) below to the extent necessary to
ensure that it is available for resales of Notes acquired by Broker-Dealers for
their own accounts as a result of market-making activities or other trading

                                        4
<Page>

activities, and to ensure that it conforms with the requirements of this
Agreement, the Securities Act and the policies, rules and regulations of the
Commission as announced from time to time, for a period ending on the earlier of
(i) 180 days from the date on which the Exchange Offer Registration Statement is
declared effective and (ii) the date on which a Broker-Dealer is no longer
required to deliver a prospectus in connection with market-making or other
trading activities.

     The Issuers shall provide sufficient copies of the latest version of such
Prospectus to Broker-Dealers promptly upon reasonable request at any time during
such 180-day (or shorter as provided in the foregoing sentence) period in order
to facilitate such resales.

     SECTION 4. SHELF REGISTRATION.

     (a) SHELF REGISTRATION. If (i) the Issuers are not required to file an
Exchange Offer Registration Statement or to consummate the Exchange Offer
because the Exchange Offer is not permitted by applicable law or Commission
interpretation or policy (after the procedures set forth in Section 6(a) below
have been complied with), (ii) for any reason the Exchange Offer is not
Consummated within 30 business days after the Exchange Offer Registration
Statement was declared effective, or (iii) with respect to any Holder of
Transfer Restricted Securities (A) such Holder is prohibited by applicable law
or Commission interpretation or policy from participating in the Exchange Offer
through no fault of the Holder, or (B) such Holder may not resell the Exchange
Notes acquired by it in the Exchange Offer to the public without delivering a
prospectus and the Prospectus is not appropriate or available for such resales
by such Holder, or (C) such Holder is a Broker-Dealer and holds Initial Notes
acquired directly from the Issuers or one of their affiliates, then, upon such
Holder's request, the Issuers shall:

           (x) use their best efforts to file a shelf registration statement
     pursuant to Rule 415 under the Securities Act, which may be an amendment to
     the Exchange Offer Registration Statement (in either event, the "SHELF
     REGISTRATION STATEMENT") on or prior to the 60th day after the earliest
     date on which the Issuers' obligation to file such Shelf Registration
     Statement as set forth in clauses (i) through (iii) above arises (such date
     being the "SHELF FILING DEADLINE"), which Shelf Registration Statement
     shall provide for resales of all Transfer Restricted Securities the Holders
     of which shall have provided all of the information required pursuant to,
     and in accordance with the deadline set forth in, Section 4(b) hereof; and

           (y) assuming the subject Holders have complied with Section 4(b)
     hereof, use their best efforts to cause such Shelf Registration Statement
     to be declared effective by the Commission on or before the 90th day after
     the Shelf Filing Deadline.

     Assuming compliance by the Holders of Section 4(b) hereof, the Issuers
shall use their best efforts to keep such Shelf Registration Statement
continuously effective, supplemented and amended as required by the provisions
of Sections 6(b) and (c) hereof to the extent necessary to ensure that it is
available for resales of Notes by the Holders of Transfer Restricted Securities
entitled to the benefit of this Section 4(a), and to ensure that it conforms
with the requirements of this Agreement, the Securities Act and the policies,
rules and regulations of the Commission as announced from time to time, for a
period of at least two years following the effective date of

                                        5
<Page>

such Shelf Registration Statement (or shorter period that will terminate when
all the Notes covered by such Shelf Registration Statement have been sold
pursuant to such Shelf Registration Statement).

     (b) PROVISION BY HOLDERS OF CERTAIN INFORMATION IN CONNECTION WITH THE
SHELF REGISTRATION STATEMENT. No Holder may include any of its Transfer
Restricted Securities in any Shelf Registration Statement pursuant to this
Agreement unless and until such Holder furnishes to the Issuers in writing,
within 20 business days after receipt of a request therefor, such information as
the Issuers may reasonably request, from time to time, for use in connection
with any Shelf Registration Statement or Prospectus or preliminary Prospectus
included therein. Each Holder as to which any Shelf Registration Statement is
being effected agrees to furnish promptly to the Issuers all information
required to be disclosed in order to make the information previously furnished
to the Issuers by such Holder not materially misleading.

     SECTION 5. LIQUIDATED DAMAGES. If (i) any of the Registration Statements
required by this Agreement is not filed with the Commission on or prior to the
date specified for such filing in this Agreement, (ii) any of such Registration
Statements has not been declared effective by the Commission on or prior to the
date specified for such effectiveness in this Agreement (the "EFFECTIVENESS
TARGET DATE"), (iii) the Exchange Offer has not been Consummated within 30
business days after the Effectiveness Target Date with respect to the Exchange
Offer Registration Statement or (iv) any Registration Statement required by this
Agreement is filed and declared effective but shall thereafter cease to be
effective or fails to be usable for its intended purpose without being succeeded
immediately by a post-effective amendment to such Registration Statement that
cures such failure and that is itself immediately declared effective (each such
event referred to in clauses (i) through (iv), a "REGISTRATION DEFAULT"), the
Issuers hereby jointly and severally agree to pay to each Holder affected
thereby liquidated damages in an amount equal to $0.05 per week per $1,000
principal amount of Transfer Restricted Securities held by such Holder for each
week or portion thereof that the Registration Default continues for the first
90-day period immediately following the occurrence of any Registration Default
("LIQUIDATED DAMAGES"). The amount of Liquidated Damages shall increase an
additional $0.05 per week per $1,000 principal amount of Transfer Restricted
Securities with respect to each subsequent 90-day period until all Registration
Defaults have been cured, up to a maximum amount of Liquidated Damages for all
Registration Defaults of $0.40 per week per $1,000 principal amount of Transfer
Restricted Securities. All accrued Liquidated Damages will be paid by the
Issuers on the next scheduled Interest Payment Date to the Holders as set forth
in the Indenture. Following the cure of all Registration Defaults relating to
any particular Transfer Restricted Securities, Liquidated Damages payable with
respect to Transfer Restricted Securities as a result of such Registration
Defaults as set forth in clauses (i) through (iv) as applicable shall cease;
PROVIDED, HOWEVER, that, if, after the time at which such Liquidated Damages
cease to accrue, a different Registration Default occurs, then Liquidated
Damages shall again accrue on the relevant Transfer Restricted Securities
pursuant to the foregoing provisions.

     All obligations of the Issuers set forth in the preceding paragraph that
are outstanding with respect to any Transfer Restricted Security at the time
such security ceases to be a Transfer Restricted Security shall survive until
such time as all such obligations with respect to such Note shall have been
satisfied in full.

                                        6
<Page>

     SECTION 6. REGISTRATION PROCEDURES.

     (a) EXCHANGE OFFER REGISTRATION STATEMENT. In connection with the Exchange
Offer, the Issuers shall comply with all of the provisions of Section 6(c)
below, shall use their best efforts to effect the Exchange Offer to permit the
sale of Transfer Restricted Securities being sold in accordance with the
intended method or methods of distribution thereof, and shall comply with all of
the following provisions:

           (i) If in the reasonable opinion of counsel to the Issuers there is a
     question as to whether the Exchange Offer is permitted by applicable law,
     the Issuers hereby agree to seek a no-action letter or other favorable
     decision from the Commission allowing the Issuers to Consummate an Exchange
     Offer for such Initial Notes. The Issuers each hereby agree to pursue
     reasonably the issuance of such a decision to the Commission staff level
     but shall not be required to take commercially unreasonable action to
     effect a change of Commission policy. The Issuers each hereby agree,
     however, to (A) participate in telephonic conferences with the Commission,
     (B) deliver to the Commission staff an analysis prepared by counsel to the
     Issuers setting forth the legal bases, if any, upon which such counsel has
     concluded that such an Exchange Offer should be permitted and (C)
     diligently pursue a favorable resolution by the Commission staff of such
     submission.

           (ii) As a condition to its participation in the Exchange Offer
     pursuant to the terms of this Agreement, each Holder shall furnish, upon
     the request of the Issuers, prior to the Consummation thereof, a written
     representation to the Issuers (which may be contained in the letter of
     transmittal contemplated by the Exchange Offer Registration Statement) to
     the effect that (A) it is not an affiliate of the Issuers, (B) it is not
     engaged in, and does not intend to engage in, and has no arrangement or
     understanding with any person to participate in, a distribution of the
     Exchange Notes to be issued in the Exchange Offer and (C) it is acquiring
     the Exchange Notes in its ordinary course of business. In addition, all
     such Holders shall otherwise cooperate in the Issuers' preparations for the
     Exchange Offer. Each Holder hereby acknowledges and agrees that any
     Broker-Dealer and any such Holder using the Exchange Offer to participate
     in a distribution of the securities to be acquired in the Exchange Offer
     (1) could not under Commission policy as in effect on the date of this
     Agreement rely on the position of the Commission enunciated in MORGAN
     STANLEY AND CO., INC. (available June 5, 1991) and EXXON CAPITAL HOLDINGS
     CORPORATION (available May 13, 1988), as interpreted in the Commission's
     letter to Shearman & Sterling dated July 2, 1993, and similar no-action
     letters (which may include any no-action letter obtained pursuant to clause
     (i) above), and (2) must comply with the registration and prospectus
     delivery requirements of the Securities Act in connection with a secondary
     resale transaction and that such a secondary resale transaction should be
     covered by an effective registration statement containing the selling
     security holder information required by Item 507 or 508, as applicable, of
     Regulation S-K if the resales are of Exchange Notes obtained by such Holder
     in exchange for Initial Notes acquired by such Holder directly from the
     Issuers.

     (b) SHELF REGISTRATION STATEMENT. In connection with the Shelf Registration
Statement, the Issuers shall comply with all the provisions of Section 6(c)
below and shall use their best

                                        7
<Page>

efforts to effect such registration to permit the sale of the Transfer
Restricted Securities being sold in accordance with the intended method or
methods of distribution thereof, and pursuant thereto the Issuers will as
expeditiously as possible prepare and file with the Commission a Registration
Statement relating to the registration on any appropriate form under the
Securities Act, which form shall be available for the sale of the Transfer
Restricted Securities in accordance with the intended method or methods of
distribution thereof.

     (c) GENERAL PROVISIONS. In connection with any Registration Statement and
any Prospectus required by this Agreement to permit the sale or resale of
Transfer Restricted Securities (including, without limitation, any Registration
Statement and the related Prospectus required to permit resales of Notes by
Broker-Dealers), the Issuers shall:

           (i) use their best efforts to keep such Registration Statement
     continuously effective and provide all requisite financial statements for
     the period specified in Section 3 or 4 of this Agreement, as applicable;
     upon the occurrence of any event that would cause any such Registration
     Statement or the Prospectus contained therein (A) to contain a material
     misstatement or omission or (B) not to be effective and usable for resale
     of Transfer Restricted Securities during the period required by this
     Agreement, the Issuers shall file promptly an appropriate amendment to such
     Registration Statement, in the case of clause (A), correcting any such
     misstatement or omission, and, in the case of either clause (A) or (B), use
     their best efforts to cause such amendment to be declared effective and
     such Registration Statement and the related Prospectus to become usable for
     their intended purpose(s) as soon as practicable thereafter;

           (ii) prepare and file with the Commission such amendments and
     post-effective amendments to the Registration Statement as may be necessary
     to keep the Registration Statement effective for the applicable period set
     forth in Section 3 or 4 hereof, as applicable, or such shorter period as
     will terminate when all Transfer Restricted Securities covered by such
     Registration Statement have been sold; cause the Prospectus to be
     supplemented by any required Prospectus supplement, and as so supplemented
     to be filed pursuant to Rule 424 under the Securities Act, and to comply
     fully with the applicable provisions of Rules 424 and 430A under the
     Securities Act in a timely manner; and comply with the provisions of the
     Securities Act with respect to the disposition of all securities covered by
     such Registration Statement during the applicable period in accordance with
     the intended method or methods of distribution by the sellers thereof set
     forth in such Registration Statement or supplement to the Prospectus;

           (iii) advise the underwriter(s), if any, and selling Holders promptly
     and, if requested by such Persons, to confirm such advice in writing, (A)
     when the Prospectus or any Prospectus supplement or post-effective
     amendment thereto has been filed, and, with respect to any Registration
     Statement or any post-effective amendment thereto, when the same has become
     effective, (B) of any request by the Commission for amendments to the
     Registration Statement or amendments or supplements to the Prospectus or
     for additional information relating thereto, (C) of the issuance by the
     Commission of any stop order suspending the effectiveness of the
     Registration Statement under the Securities Act or of the suspension by any
     state securities commission of the qualification of the Transfer Restricted
     Securities for offering or sale in any jurisdiction, or the initiation of
     any

                                        8
<Page>

     proceeding for any of the preceding purposes, (D) of the existence of any
     fact or the happening of any event that makes any statement of a material
     fact (x) made in the Registration Statement, any amendment or supplement
     thereto, or any document incorporated by reference therein, untrue or omits
     to state a material fact required to be stated therein or necessary to make
     the statements therein not misleading, (y) made in the Prospectus, any
     amendment or supplement thereto, or any document incorporated by reference
     therein, untrue or omits to state a material fact required to be stated
     therein in order to make the statements therein, in the light of the
     circumstances under which they were made, not misleading, or (z) that
     requires the making of any additions to or changes in the Registration
     Statement or the Prospectus in order to make the statements therein not
     misleading. If at any time the Commission shall issue any stop order
     suspending the effectiveness of the Registration Statement, or any state
     securities commission or other regulatory authority shall issue an order
     suspending the qualification or exemption from qualification of the
     Transfer Restricted Securities under state securities or Blue Sky laws, the
     Issuers shall use their best efforts to obtain the withdrawal or lifting of
     such order at the earliest possible time;

           (iv) furnish without charge to each of the Initial Purchasers, each
     selling Holder named in any Registration Statement, and each of the
     underwriter(s), if any, before filing with the Commission, copies of any
     Registration Statement, which will be subject to the review of such Holders
     and underwriter(s) in connection with such sale, if any, for a period of at
     least five business days, and the Issuers will not file any such
     Registration Statement to which an Initial Purchaser of Transfer Restricted
     Securities covered by such Registration Statement or the underwriter(s), if
     any, shall reasonably object in writing within five business days after the
     receipt thereof (such objection to be deemed timely made upon confirmation
     of telecopy transmission within such period). The objection of an Initial
     Purchaser or underwriter, if any, shall be deemed to be reasonable if such
     Registration Statement, as proposed to be filed, contains a material
     misstatement or omission;

           (v) promptly prior to the filing of any document that is to be
     incorporated by reference into a Registration Statement or Prospectus,
     provide copies of such document to the Initial Purchasers, each selling
     Holder named in any Registration Statement, and to the underwriter(s), if
     any, make the Issuers' representatives available for discussion of such
     document and other customary due diligence matters, and include such
     information in such document prior to the filing thereof as such selling
     Holders or underwriter(s), if any, reasonably may request;

           (vi) make available at reasonable times for inspection by the Initial
     Purchasers, any managing underwriter participating in any disposition
     pursuant to such Registration Statement and any attorney or accountant
     retained by such Initial Purchasers or any of the underwriter(s), all
     financial and other records, pertinent and material corporate documents and
     pertinent and material properties of the Issuers and cause the Issuers'
     officers, directors and employees to supply all such pertinent and material
     information reasonably requested by any such Holder, underwriter, attorney
     or accountant in connection with such Registration Statement subsequent to
     the filing thereof and prior to its effectiveness;

                                        9
<Page>

           (vii) if requested by any selling Holders or the underwriter(s), if
     any, promptly incorporate in any Registration Statement or Prospectus,
     pursuant to a supplement or post-effective amendment if necessary, such
     information as such selling Holders and underwriter(s), if any, may
     reasonably request to have included therein, including, without limitation,
     information relating to the "Plan of Distribution" of the Transfer
     Restricted Securities, information with respect to the principal amount of
     Transfer Restricted Securities being sold to such underwriter(s), the
     purchase price being paid therefor and any other terms of the offering of
     the Transfer Restricted Securities to be sold in such offering; and make
     all required filings of such Prospectus supplement or post-effective
     amendment as soon as practicable after the Issuers are notified of, and
     provided with the applicable information relating to, the matters to be
     incorporated in such Prospectus supplement or post-effective amendment;

           (viii) cause the Transfer Restricted Securities covered by the
     Registration Statement to be rated with the appropriate rating agencies, if
     so requested by the Holders of a majority in aggregate principal amount of
     Notes covered thereby or the underwriter(s), if any;

           (ix) furnish to each selling Holder and each of the underwriter(s),
     if any, without charge, at least one copy of the Registration Statement, as
     first filed with the Commission, and of each amendment thereto, including
     financial statements and schedules, all documents incorporated by reference
     therein and all exhibits (including exhibits incorporated therein by
     reference);

           (x) deliver to each selling Holder and each of the underwriter(s), if
     any, without charge, as many copies of the Prospectus (including each
     preliminary prospectus) and any amendment or supplement thereto as such
     Persons reasonably may request; the Issuers hereby consent to the use of
     the Prospectus and any amendment or supplement thereto by each of the
     selling Holders and each of the underwriter(s), if any, in connection with
     the offering and the sale of the Transfer Restricted Securities covered by
     the Prospectus or any amendment or supplement thereto;

           (xi) enter into such customary agreements (including an underwriting
     agreement), and make such customary representations and warranties, and
     take all such other reasonable actions in connection therewith in order to
     expedite or facilitate the disposition of the Transfer Restricted
     Securities pursuant to any Registration Statement contemplated by this
     Agreement, all to such extent as may be reasonably requested by any Initial
     Purchaser or by any Holder of Transfer Restricted Securities or underwriter
     in connection with any sale or resale pursuant to any Registration
     Statement contemplated by this Agreement; and whether or not an
     underwriting agreement is entered into and whether or not the registration
     is an Underwritten Registration, the Issuers shall:

                  (A) furnish to each Initial Purchaser, each selling Holder and
           each underwriter, if any, in such substance and scope as they may
           request and as are customarily made by issuers to underwriters in
           primary underwritten offerings, upon the date of the Consummation of
           the Exchange Offer and, if applicable, the effectiveness of the Shelf
           Registration Statement:

                                       10
<Page>

                        (1) a certificate, dated the date of Consummation of
                  the Exchange Offer or the date of effectiveness of the Shelf
                  Registration Statement, as the case may be, signed by the
                  Chairman of the Board, the Chief Executive Officer or the
                  President of each of the Issuers, confirming, as of the date
                  thereof, the matters set forth in paragraphs (i), (ii) and
                  (iii) of Section 5(g) of the Purchase Agreement and such other
                  matters as such parties may reasonably request;

                        (2) an opinion or opinions, dated the date of
                  Consummation of the Exchange Offer or the date of
                  effectiveness of the Shelf Registration Statement, as the case
                  may be, of counsel for the Issuers, covering the matters set
                  forth in paragraphs (d) and (e) of Section 5 of the Purchase
                  Agreement and such other securities law matters as are
                  customarily addressed in legal opinions in transactions
                  pursuant to shelf registration statements, and in any event
                  including a statement to the effect that such counsel has
                  participated in conferences with officers and other
                  representatives of the Issuers, representatives of the
                  independent public accountants for the Issuers, the Initial
                  Purchasers' representatives and the Initial Purchasers'
                  counsel in connection with the preparation of such
                  Registration Statement and the related Prospectus and have
                  considered the matters required to be stated therein and the
                  statements contained therein, although such counsel has not
                  independently verified the accuracy, completeness or fairness
                  of such statements; and that such counsel advises that, on the
                  basis of the foregoing (relying as to materiality to a large
                  extent upon facts provided to such counsel by officers and
                  other representatives of the Issuers and without independent
                  check or verification), no facts came to such counsel's
                  attention that caused such counsel to believe that the
                  applicable Registration Statement, at the time such
                  Registration Statement or any post-effective amendment thereto
                  became effective, and, in the case of the Exchange Offer
                  Registration Statement, as of the date of Consummation,
                  contained an untrue statement of a material fact or omitted to
                  state a material fact required to be stated therein or
                  necessary to make the statements therein not misleading, or
                  that the Prospectus contained in such Registration Statement
                  as of its date and, in the case of the opinion dated the date
                  of Consummation of the Exchange Offer, as of the date of
                  Consummation, contained an untrue statement of a material fact
                  or omitted to state a material fact necessary in order to make
                  the statements therein, in light of the circumstances under
                  which they were made, not misleading. Without limiting the
                  foregoing, such counsel may state further that such counsel
                  assumes no responsibility for, and has not independently
                  verified, the accuracy, completeness or fairness of the
                  financial statements, notes and schedules and other financial
                  data included in any Registration Statement contemplated by
                  this Agreement or the related Prospectus; and

                        (3) a customary comfort letter, dated as of the date of
                  Consummation of the Exchange Offer or the date of
                  effectiveness of the

                                       11
<Page>

                  Shelf Registration Statement, as the case may be, from the
                  Issuers' independent accountants, in the customary form and
                  covering matters of the type customarily covered in comfort
                  letters by underwriters in connection with primary
                  underwritten offerings, and affirming the matters set forth in
                  the comfort letter delivered pursuant to Section 5[(b)] of the
                  Purchase Agreement, without exception;

                  (B) set forth in full or incorporate by reference in the
           underwriting agreement, if any, the indemnification provisions and
           procedures of Section 8 hereof with respect to all parties to be
           indemnified pursuant to said Section; and

                  (C) deliver such other documents and certificates as may be
           reasonably requested by such parties to evidence compliance with
           clause (A) above and with any customary conditions contained in the
           underwriting agreement or other agreement entered into by the Issuers
           pursuant to this clause (xi), if any.

           If at any time the representations and warranties of the Issuers
     contemplated in clause (A)(1) above cease to be true and correct, the
     Issuers shall so advise the Initial Purchasers and the underwriter(s), if
     any, and each selling Holder promptly and, if requested by such Persons,
     shall confirm such advice in writing;

           (xii) prior to any public offering of Transfer Restricted Securities,
     cooperate with the selling Holders, the underwriter(s), if any, and their
     respective counsel in connection with the registration and qualification of
     the Transfer Restricted Securities under the securities or Blue Sky laws of
     such jurisdictions as the selling Holders or underwriter(s) may request and
     do any and all other acts or things necessary or advisable to enable the
     disposition in such jurisdictions of the Transfer Restricted Securities
     covered by the Shelf Registration Statement; PROVIDED, HOWEVER, that the
     Issuers shall not be required to register or qualify as foreign
     corporations where they are not then so qualified or to take any action
     that would subject either of the Issuers to the service of process in suits
     or to taxation, other than as to matters and transactions relating to the
     Registration Statement, in any jurisdiction where they are not then so
     subject;

           (xiii) shall issue, upon the request of any Holder of Initial Notes
     covered by the Shelf Registration Statement, Exchange Notes having an
     aggregate principal amount equal to the aggregate principal amount of
     Initial Notes surrendered to the Issuers by such Holder in exchange
     therefor or being sold by such Holder; such Exchange Notes to be registered
     in the name of such Holder or in the name of the purchaser(s) of such
     Notes, as the case may be; in return, the Initial Notes held by such Holder
     shall be promptly surrendered to the Issuers for cancellation;

           (xiv) cooperate with the selling Holders and the underwriter(s), if
     any, to facilitate the timely preparation and delivery of certificates
     representing Transfer Restricted Securities to be sold and not bearing any
     restrictive legends when no longer required; and enable such Transfer
     Restricted Securities to be in such denominations and registered in such
     names as the Holders or the underwriter(s), if any, may request at least

                                       12
<Page>

     two business days prior to any sale of Transfer Restricted Securities made
     by such underwriter(s);

           (xv) use their best efforts to cause the Transfer Restricted
     Securities covered by the Registration Statement to be registered with or
     approved by such other governmental agencies or authorities as may be
     necessary to enable the seller or sellers thereof or the underwriter(s), if
     any, to consummate the disposition of such Transfer Restricted Securities,
     subject to the proviso contained in clause (xii) above;

           (xvi) if any fact or event contemplated by clause (c)(iii)(D) above
     shall exist or have occurred, prepare a supplement or post-effective
     amendment to the Registration Statement or related Prospectus or any
     document incorporated therein by reference or file any other required
     document so that, as thereafter delivered to the purchasers of Transfer
     Restricted Securities, the Prospectus will not contain an untrue statement
     of a material fact or omit to state any material fact necessary to make the
     statements therein, in light of the circumstances under which they were
     made, not misleading;

           (xvii) provide a CUSIP number for all Transfer Restricted Securities
     not later than the effective date of the Registration Statement and provide
     the Trustee under the Indenture with printed certificates for the Transfer
     Restricted Securities which are in a form eligible for deposit with the
     Depositary Trust Company;

           (xviii) cooperate and assist in any filings required to be made with
     the NASD and in the performance of any due diligence investigation by any
     underwriter (including any "qualified independent underwriter") that is
     required to be retained in accordance with the rules and regulations of the
     NASD, and use their respective reasonable best efforts to cause such
     Registration Statement to become effective and approved by such
     governmental agencies or authorities as may be necessary to enable the
     Holders selling Transfer Restricted Securities to consummate the
     disposition of such Transfer Restricted Securities;

           (xix) otherwise use their respective best efforts to comply with all
     applicable rules and regulations of the Commission, and make generally
     available to their security holders, as soon as practicable, consolidated
     earnings statements meeting the requirements of Rule 158 (which need not be
     audited) for the twelve-month period (A) commencing at the end of any
     fiscal quarter in which Transfer Restricted Securities are sold to
     underwriters in a firm or best efforts Underwritten Offering or (B) if not
     sold to underwriters in such an offering, beginning with the first month of
     the Issuers' first fiscal quarter commencing after the effective date of
     the Registration Statement;

           (xx) cause the Indenture to be qualified under the Trust Indenture
     Act not later than the effective date of the first Registration Statement
     required by this Agreement, and, in connection therewith, cooperate with
     the Trustee and the Holders of Notes to effect such changes to the
     Indenture as may be required for such Indenture to be so qualified in
     accordance with the terms of the Trust Indenture Act; and to execute, and
     use their respective best efforts to cause the Trustee to execute, all
     documents that may be

                                       13
<Page>

     required to effect such changes and all other forms and documents required
     to be filed with the Commission to enable such Indenture to be so qualified
     in a timely manner;

           (xxi) cause all Transfer Restricted Securities covered by the
     Registration Statement to be listed on each securities exchange on which
     similar securities issued by the Issuers are then listed if requested by
     the Holders of a majority in aggregate principal amount of Initial Notes or
     the managing underwriter(s), if any; and

           (xxii) provide promptly to each Holder upon request each document
     filed with the Commission pursuant to the requirements of Section 13 and
     Section 15 of the Exchange Act, unless otherwise available through the
     Commission's EDGAR database.

     Each Holder agrees by acquisition of a Transfer Restricted Security that,
upon receipt of any notice from the Issuers of the existence of any fact of the
kind described in Section 6(c)(iii)(D) hereof, such Holder will forthwith
discontinue disposition of Transfer Restricted Securities pursuant to the
applicable Registration Statement until such Holder's receipt of the copies of
the supplemented or amended Prospectus contemplated by Section 6(c)(xvi) hereof,
or until it is advised in writing (the "ADVICE") by the Issuers that the use of
the Prospectus may be resumed, and has received copies of any additional or
supplemental filings that are incorporated by reference in the Prospectus. If so
directed by the Issuers, each Holder will deliver to the Issuers (at the
Issuers' expense) all copies, other than permanent file copies then in such
Holder's possession, of the Prospectus covering such Transfer Restricted
Securities that was current at the time of receipt of such notice. In the event
the Issuers shall give any such notice, the time period regarding the
effectiveness of such Registration Statement set forth in Section 3 or 4 hereof,
as applicable, shall be extended by the number of days during the period from
and including the date of the giving of such notice pursuant to Section
6(c)(iii)(D) hereof to and including the date when each selling Holder covered
by such Registration Statement shall have received the copies of the
supplemented or amended Prospectus contemplated by Section 6(c)(xvi) hereof or
shall have received the Advice; however, no such extension shall be taken into
account in determining whether Liquidated Damages are due pursuant to Section 5
hereof or the amount of such Liquidated Damages, it being agreed that the
Issuers' option to suspend use of a Registration Statement pursuant to this
paragraph shall be treated as a Registration Default for purposes of Section 5.

     SECTION 7. REGISTRATION EXPENSES.

     (a) All expenses incident to the Issuers' performance of or compliance with
this Agreement will be borne by the Issuers, regardless of whether a
Registration Statement becomes effective, including without limitation: (i) all
registration and filing fees and expenses (including filings made by any Initial
Purchaser or Holder with the NASD (and, if applicable, the fees and expenses of
any "qualified independent underwriter" and its counsel that may be required by
the rules and regulations of the NASD)); (ii) all fees and expenses of
compliance with federal securities and state Blue Sky or securities laws; (iii)
all expenses of printing (including printing certificates for the Exchange Notes
to be issued in the Exchange Offer and printing of Prospectuses), messenger and
delivery services and telephone; (iv) all fees and disbursements of counsel for
the Issuers and, subject to Section 7(b) below, the Holders of Transfer
Restricted Securities; (v) all application and filing fees in connection with
listing the Exchange Notes on a

                                       14
<Page>

national securities exchange or automated quotation system pursuant to the
requirements thereof; and (vi) all fees and disbursements of independent
certified public accountants of the Issuers (including the expenses of any
special audit and comfort letters required by or incident to such performance).

     The Issuers will, in any event, bear their respective internal expenses
(including, without limitation, all salaries and expenses of their officers and
employees performing legal or accounting duties), the expenses of any annual
audit and the fees and expenses of any Person, including special experts,
retained by the Issuers.

     (b) In connection with any Registration Statement required by this
Agreement (including, without limitation, the Exchange Offer Registration
Statement and the Shelf Registration Statement), the Issuers will reimburse the
Initial Purchasers and the Holders of Transfer Restricted Securities being
tendered in the Exchange Offer and/or resold pursuant to the "Plan of
Distribution" contained in the Exchange Offer Registration Statement or
registered pursuant to the Shelf Registration Statement, as applicable, for the
reasonable fees and disbursements of not more than one counsel, who shall be
Latham & Watkins LLP or such other counsel as may be chosen by the Holders of a
majority in principal amount of the Transfer Restricted Securities for whose
benefit such Registration Statement is being prepared.

     SECTION 8. INDEMNIFICATION.

     (a) The Issuers, jointly and severally, agree to indemnify and hold
harmless (i) each Holder and (ii) each person, if any, who controls (within the
meaning of Section 15 of the Securities Act or Section 20 of the Exchange Act)
any Holder (any of the persons referred to in this clause (ii) being hereinafter
referred to as a "CONTROLLING PERSON") and (iii) the respective officers,
directors, partners, employees, representatives and agents of any Holder or any
controlling person (any person referred to in clause (i), (ii) or (iii) may
hereinafter be referred to as an "INDEMNIFIED HOLDER"), to the fullest extent
lawful, from and against any and all losses, claims, damages, liabilities,
judgments, actions and expenses (including without limitation and as incurred,
reimbursement of all reasonable costs of investigating, preparing, pursuing,
settling, compromising, paying or defending any claim or action, or any
investigation or proceeding by any governmental agency or body, commenced or
threatened, including the reasonable fees and expenses of counsel to any
Indemnified Holder), joint or several, directly or indirectly caused by, related
to, based upon, arising out of or in connection with any untrue statement or
alleged untrue statement of a material fact contained in any Registration
Statement or Prospectus (or any amendment or supplement thereto), or any
omission or alleged omission to state therein a material fact required to be
stated therein or necessary to make the statements therein not misleading,
except insofar as such losses, claims, damages, liabilities or expenses are
caused by an untrue statement or omission or alleged untrue statement or
omission that is made in reliance upon and in conformity with information
relating to any of the Holders furnished in writing to the Issuers by any such
Holder expressly for use therein. This indemnity agreement shall be in addition
to any liability which the Issuers may otherwise have.

     In case any action or proceeding (including any governmental or regulatory
investigation or proceeding) shall be brought or asserted against any of the
Indemnified Holders with respect to which indemnity may be sought against either
of the Issuers, such Indemnified Holder (or the

                                       15
<Page>

Indemnified Holder controlled by such controlling person) shall promptly notify
the Issuers in writing (PROVIDED, that the failure to give such notice shall not
relieve the Issuers of their respective obligations pursuant to this Agreement).
Such Indemnified Holder shall have the right to employ its own counsel in any
such action and the reasonable fees and expenses of such counsel shall be paid,
as incurred, by the Issuers (regardless of whether it is ultimately determined
that an Indemnified Holder is not entitled to indemnification hereunder). The
Issuers shall not, in connection with any one such action or proceeding or
separate but substantially similar or related actions or proceedings in the same
jurisdiction arising out of the same general allegations or circumstances, be
liable for the reasonable fees and expenses of more than one separate firm of
attorneys (in addition to any local counsel) at any time for such Indemnified
Holders, which firm shall be designated by the Holders. The Issuers shall be
liable for any settlement of any such action or proceeding effected with each of
the Issuers' prior written consent, which consent shall not be withheld
unreasonably, and the Issuers agree to indemnify and hold harmless any
Indemnified Holder from and against any loss, claim, damage, liability or
expense by reason of any settlement of any action effected with the written
consent of the Issuers. The Issuers shall not, without the prior written consent
of each Indemnified Holder, settle or compromise or consent to the entry of
judgment in or otherwise seek to terminate any pending or threatened action,
claim, litigation or proceeding in respect of which indemnification or
contribution may be sought hereunder (whether or not any Indemnified Holder is a
party thereto), unless such settlement, compromise, consent or termination
includes an unconditional release of each Indemnified Holder from all liability
arising out of such action, claim, litigation or proceeding.

     (b) Each Holder of Transfer Restricted Securities agrees, severally and not
jointly, to indemnify and hold harmless the Issuers and their respective
directors, officers who sign a Registration Statement and any person controlling
(within the meaning of Section 15 of the Securities Act or Section 20 of the
Exchange Act) either of the Issuers, and the respective officers, directors,
partners, employees, representatives and agents of each such person, to the same
extent as the foregoing indemnity from the Issuers to each of the Indemnified
Holders, but only with respect to claims and actions based on information
relating to such Holder furnished in writing by such Holder expressly for use in
any Registration Statement or relating to information omitted or not provided by
such Holder to the Issuers but otherwise required to be disclosed in the
Registration Statement. In case any action or proceeding shall be brought
against the Issuers or their respective directors or officers or any such
controlling person in respect of which indemnity may be sought against a Holder
of Transfer Restricted Securities, such Holder shall have the rights and duties
given the Issuers or their respective directors or officers or such controlling
person shall have the rights and duties given to each Holder by the preceding
paragraph.

     (c) If the indemnification provided for in this Section 8 is unavailable to
an indemnified party under Section 8(a) or Section 8(b) hereof (other than by
reason of exceptions provided in those Sections) in respect of any losses,
claims, damages, liabilities, judgments, actions or expenses referred to
therein, then each applicable indemnifying party, in lieu of indemnifying such
indemnified party, shall contribute to the amount paid or payable by such
indemnified party as a result of such losses, claims, damages, liabilities or
expenses in such proportion as is appropriate to reflect the relative benefits
received by each of the Issuers, on the one hand, and the Holders, on the other
hand, from the Initial Placement (which in the case of the Issuers shall

                                       16
<Page>

be deemed to be equal to the total gross proceeds from the Initial Placement as
set forth on the cover page of the Offering Memorandum) the amount of Liquidated
Damages which did not become payable as a result of the filing of the
Registration Statement resulting in such losses, claims, damages, liabilities,
judgments, actions or expenses, and such Registration Statement, or if such
allocation is not permitted by applicable law, the relative fault of the Issuers
on the one hand, and of the Holders, on the other hand, in connection with the
statements or omissions which resulted in such losses, claims, damages,
liabilities, judgments, actions or expenses, as well as any other relevant
equitable considerations. The relative fault of the Issuers on the one hand and
of the Indemnified Holder on the other shall be determined by reference to,
among other things, whether the untrue or alleged untrue statement of a material
fact or the omission or alleged omission to state a material fact relates to
information supplied by the Issuers or by the Indemnified Holder and the
parties' relative intent, knowledge, access to information and opportunity to
correct or prevent such statement or omission. The amount paid or payable by a
party as a result of the losses, claims, damages, liabilities, judgments,
actions and expenses referred to above shall be deemed to include, subject to
the limitations set forth in the second paragraph of Section 8(a), any legal or
other fees or expenses reasonably incurred by such party in connection with
investigating or defending any action or claim.

     The Issuers and each Holder of Transfer Restricted Securities agree that it
would not be just and equitable if contribution pursuant to this Section 8(c)
were determined by pro rata allocation (even if the Holders were treated as one
entity for such purpose) or by any other method of allocation which does not
take account of the equitable considerations referred to in the immediately
preceding paragraph. The amount paid or payable by an indemnified party as a
result of the losses, claims, damages, liabilities, judgments, actions or
expenses referred to in the immediately preceding paragraph shall be deemed to
include, subject to the limitations set forth above, any legal or other expenses
reasonably incurred by such indemnified party in connection with investigating
or defending any such action or claim. Notwithstanding the provisions of this
Section 8, none of the Holders (and its related Indemnified Holders) shall be
required to contribute, in the aggregate, any amount in excess of the amount by
which the total discount received by such Holder with respect to the Initial
Notes exceeds the amount of any damages which such Holder has otherwise been
required to pay by reason of such untrue or alleged untrue statement or omission
or alleged omission. No person guilty of fraudulent misrepresentation (within
the meaning of Section 11(f) of the Securities Act) shall be entitled to
contribution from any person who was not guilty of such fraudulent
misrepresentation. The Holders' obligations to contribute pursuant to this
Section 8(c) are several in proportion to the respective principal amount of
Initial Notes held by each of the Holders hereunder and not joint.

     SECTION 9. RULE 144A. The Issuers each hereby agree with each Holder, for
so long as any Transfer Restricted Securities remain outstanding, to make
available to any Holder or beneficial owner of Transfer Restricted Securities in
connection with any sale thereof and any prospective purchaser of such Transfer
Restricted Securities from such Holder or beneficial owner, the information
required by Rule 144A(d)(4) under the Securities Act in order to permit resales
of such Transfer Restricted Securities pursuant to Rule 144A.

     SECTION 10. PARTICIPATION IN UNDERWRITTEN REGISTRATIONS. No Holder may
participate in any Underwritten Registration hereunder unless such Holder (a)
agrees to sell such Holder's Transfer Restricted Securities on the basis
provided in any underwriting arrangements approved

                                       17
<Page>

by the Persons entitled hereunder to approve such arrangements and (b) completes
and executes all reasonable questionnaires, powers of attorney, indemnities,
underwriting agreements, lock-up letters and other documents required under the
terms of such underwriting arrangements.

     SECTION 11. SELECTION OF UNDERWRITERS. The Holders of Transfer Restricted
Securities covered by the Shelf Registration Statement who desire to do so may
sell such Transfer Restricted Securities in an Underwritten Offering. In any
such Underwritten Offering, the investment banker or investment bankers and
manager or managers that will administer the offering will be selected by the
Holders of a majority in aggregate principal amount of the Transfer Restricted
Securities included in such offering; PROVIDED, that such investment bankers and
managers must be reasonably satisfactory to the Issuers.

     SECTION 12. MISCELLANEOUS.

     (a) REMEDIES. The Issuers hereby agree that monetary damages would not be
adequate compensation for any loss incurred by reason of a breach by it of the
provisions of this Agreement and hereby agree to waive the defense in any action
for specific performance that a remedy at law would be adequate.

     (b) NO INCONSISTENT AGREEMENTS. The Issuers will not on or after the date
of this Agreement enter into any agreement with respect to their securities that
is inconsistent with the rights granted to the Holders in this Agreement or
otherwise conflicts with the provisions hereof. The Issuers have not previously
entered into any agreement granting any registration rights to any Person to
have any securities included in the Registration Statement. The rights granted
to the Holders hereunder do not in any way conflict with and are not
inconsistent with the rights granted to the holders of the Issuers' securities
under any agreement in effect on the date hereof.

     (c) ADJUSTMENTS AFFECTING THE NOTES. The Issuers will not take any action,
or permit any change to occur, with respect to the Notes that would materially
and adversely affect the ability of the Holders to Consummate any Exchange
Offer.

     (d) AMENDMENTS AND WAIVERS. The provisions of this Agreement may not be
amended, modified or supplemented, and waivers or consents to or departures from
the provisions hereof may not be given unless the Issuers have obtained the
written consent of Holders of a majority of the outstanding principal amount of
Transfer Restricted Securities. Notwithstanding the foregoing, a waiver or
consent to departure from the provisions hereof that relates exclusively to the
rights of Holders whose securities are being tendered pursuant to the Exchange
Offer and that does not affect directly or indirectly the rights of other
Holders whose securities are not being tendered pursuant to such Exchange Offer
may be given by the Holders of a majority of the outstanding principal amount of
Transfer Restricted Securities being tendered or registered; provided that, with
respect to any matter that directly or indirectly affects the rights of any
Initial Purchaser hereunder, the Issuers shall obtain the written consent of
each such Initial Purchaser with respect to which such amendment, qualification,
supplement, waiver, consent or departure is to be effective.

     (e) NOTICES. All notices and other communications provided for or permitted
hereunder shall be made in writing by hand-delivery, first-class mail
(registered or certified, return receipt

                                       18
<Page>

requested), telex, telecopier (with a hard copy to be promptly delivered by one
of the other methods approved hereunder), or air courier guaranteeing overnight
delivery:

           (i)  if to a Holder, at the address set forth on the records of the
     Registrar under the Indenture, with a copy to the Registrar under the
     Indenture; and

           (ii) if to the Issuers:

                  Premier Entertainment Biloxi LLC
                  (d/b/a Hard Rock Hotel & Casino Biloxi)
                  Premier Finance Corp.
                  11400 Reichold Road
                  Gulfport, MS 39503
                  Telecopier No.: (228) 896-4078
                  Attention: Joseph Billhimer

                  With a copy to:

                  Duane Morris LLP
                  227 West Monroe St.
                  Chicago, IL 60606
                  Telecopier No.: (312) 499-6701
                  Attention: Brian P. Kerwin, Esq.

     All such notices and communications shall be deemed to have been duly
given: at the time delivered by hand, if personally delivered; five business
days after being deposited in the mail, postage prepaid, if mailed; when
answered back, if telexed; when receipt acknowledged, if telecopied; and on the
next business day, if timely delivered to an air courier guaranteeing overnight
delivery.

     Copies of all such notices, demands or other communications shall be
concurrently delivered by the Person giving the same to the Trustee at the
address specified in the Indenture.

     (f) SUCCESSORS AND ASSIGNS. This Agreement shall inure to the benefit of
and be binding upon the successors and assigns of each of the parties, including
without limitation and without the need for an express assignment, subsequent
Holders of Transfer Restricted Securities; PROVIDED, HOWEVER, that this
Agreement shall not inure to the benefit of or be binding upon a successor or
assign of a Holder unless and to the extent such successor or assign acquired
Transfer Restricted Securities from such Holder.

     (g) COUNTERPARTS. This Agreement may be executed in any number of
counterparts and by the parties hereto in separate counterparts, each of which
when so executed shall be deemed to be an original and all of which taken
together shall constitute one and the same agreement.

     (h) HEADINGS. The headings in this Agreement are for convenience of
reference only and shall not limit or otherwise affect the meaning hereof.

                                       19
<Page>

     (i) GOVERNING LAW. THIS AGREEMENT SHALL BE GOVERNED BY AND CONSTRUED IN
ACCORDANCE WITH THE INTERNAL LAWS OF THE STATE OF NEW YORK, WITHOUT REGARD TO
THE CONFLICT OF LAW RULES THEREOF.

     (j) SEVERABILITY. In the event that any one or more of the provisions
contained herein, or the application thereof in any circumstance, is held
invalid, illegal or unenforceable, the validity, legality and enforceability of
any such provision in every other respect and of the remaining provisions
contained herein shall not be affected or impaired thereby.

     (k) ENTIRE AGREEMENT. This Agreement together with the other Transaction
Documents (as defined in the Purchase Agreement) is intended by the parties as a
final expression of their agreement and intended to be a complete and exclusive
statement of the agreement and understanding of the parties hereto in respect of
the subject matter contained herein. There are no restrictions, promises,
warranties or undertakings, other than those set forth or referred to herein
with respect to the registration rights granted by the Issuers with respect to
the Transfer Restricted Securities. This Agreement supersedes all prior
agreements and understandings between the parties with respect to such subject
matter.

                                       20
<Page>

     IN WITNESS WHEREOF, the parties have executed this Agreement as of the date
first written above.

                                        PREMIER ENTERTAINMENT BILOXI LLC
                                        (d/b/a Hard Rock Hotel & Casino Biloxi),
                                        a Delaware limited liability company

                                        By: /s/ Joseph Billhimer
                                           -------------------------------------
                                           Name: Joseph Billhimer
                                           Title: President, Manager and
                                                  Chief Operating Officer

                                        PREMIER FINANCE BILOXI CORP.,
                                        a Delaware corporation

                                        By: /s/ Joseph Billhimer
                                           -------------------------------------
                                           Name: Joseph Billhimer
                                           Title: President

                                       21
<Page>

     The foregoing Registration Rights Agreement is hereby confirmed and
accepted as of the date first above written:

BANC OF AMERICA SECURITIES LLC
CITIGROUP GLOBAL MARKETS INC.
MERRILL LYNCH PIERCE FENNER & SMITH INCORPORATED

By:  Banc of America Securities LLC

By:  /s/ Bruce R. Thompson
     -----------------------------------
     Name: Bruce R. Thompson
     Title: Managing Director

                                       22<Page>

                                                                     Exhibit 4.3

                   CASH COLLATERAL AND DISBURSEMENT AGREEMENT

                                      Among

                         U.S. BANK NATIONAL ASSOCIATION,
             a national banking association, as Disbursement Agent,

                         U.S. BANK NATIONAL ASSOCIATION,
                   a national banking association, as Trustee,

              PROFESSIONAL ASSOCIATES CONSTRUCTION SERVICES, INC.,
                            a California corporation

                        PREMIER ENTERTAINMENT BILOXI LLC,
                      a Delaware limited liability company

                                       and

                          PREMIER FINANCE BILOXI CORP.,
                             a Delaware corporation

                                   dated as of

                                January 23, 2004

<Page>

                                TABLE OF CONTENTS

<Table>
<Caption>
                                                                                                 PAGE
<S>  <C>                                                                                          <C>
1.   DEFINITIONS.................................................................................. 3
     1.1   DEFINED TERMS...........................................................................3
     1.2   INDEX OF ADDITIONAL DEFINED TERMS......................................................14

2.   APPOINTMENT OF DISBURSEMENT AGENT; ESTABLISHMENT OF SECURITIES
     ACCOUNTS; RELATED PROVISIONS................................................................ 15
     2.1   APPOINTMENT OF THE DISBURSEMENT AGENT................................................. 15
     2.2   ESTABLISHMENT OF ACCOUNTS............................................................. 16
     2.3   ACKNOWLEDGEMENT OF SECURITY INTEREST; CONTROL......................................... 17
     2.4   CONTROL OF SECURITIES ACCOUNTS........................................................ 17
     2.5   CONTROL OF ISSUER'S PAYMENT ACCOUNT................................................... 18
     2.6   CONTROL OF PFC PAYMENT ACCOUNT........................................................ 19
     2.7   THE ISSUER'S RIGHTS................................................................... 20
     2.8   CASH EQUIVALENTS...................................................................... 20
     2.9   REMEDIES.............................................................................. 20
     2.10  WAIVER OF SET-OFF RIGHTS.............................................................. 21
     2.11  COOPERATION........................................................................... 21
     2.12  FUNDING MECHANICS FOR FF&E COSTS...................................................... 21
     2.13  FUNDING MECHANICS FOR BOND FINANCING.................................................. 22

3.   CERTAIN RESPONSIBILITIES OF DISBURSEMENT AGENT AND INDEPENDENT
     CONSTRUCTION CONSULTANT..................................................................... 23
     3.1   DISBURSEMENTS FROM THE ACCOUNTS....................................................... 23
     3.2   TRANSFER OF FUNDS AT DIRECTION OF TRUSTEE............................................. 23
     3.3   PAYMENT OF COMPENSATION............................................................... 23
     3.4   PERIODIC REVIEW....................................................................... 24
     3.5   REVIEW BY INDEPENDENT CONSTRUCTION CONSULTANT......................................... 24
     3.6   THE SPECIAL PROCEDURES FOR UNPAID CONTRACTORS......................................... 25

4.   DISBURSEMENTS DURING CONSTRUCTION PERIOD.................................................... 25
     4.1   INITIAL DISBURSEMENTS FROM THE CONSTRUCTION DISBURSEMENT ACCOUNT...................... 25
     4.2   SUBSEQUENT DISBURSEMENTS FROM THE CONSTRUCTION DISBURSEMENT ACCOUNT. ................. 26
     4.3   ADVANCE CONSTRUCTION DISBURSEMENTS.................................................... 31
     4.4   INTEREST RESERVE ACCOUNT DISBURSEMENTS................................................ 32
     4.5   ISSUER'S REIMBURSEMENT OF PREVIOUSLY FUNDED PROJECT COSTS............................. 33
     4.6   DISBURSEMENT OF FUNDS IN CONSTRUCTION PERIOD ACCOUNTS FOLLOWING
           THE INITIAL OPERATING DATE............................................................ 33
     4.7   FINAL DISBURSEMENT OF FUNDS IN CONSTRUCTION PERIOD ACCOUNTS........................... 35
     4.8   TIDELANDS LEASE DISBURSEMENTS......................................................... 36

5.   CERTAIN CONSTRUCTION PERIOD COVENANTS....................................................... 36
     5.1   AMENDMENTS TO PROJECT BUDGET.......................................................... 36
     5.2   CONSTRUCTION CONTRACT AMENDMENT PROCESS............................................... 38
     5.3   CONSTRUCTION CONTRACTS ENTERED INTO AFTER THE ISSUANCE DATE........................... 38
     5.4   AVAILABLE CONSTRUCTION FUNDS CERTIFICATE.............................................. 39
     5.5   PROJECT COST SCHEDULE CERTIFICATE..................................................... 40
     5.6   FINAL PLANS........................................................................... 40
     5.7   NOTICE THAT PROJECT IS OPERATING...................................................... 40
     5.8   MAINTENANCE OF PERMITTED INVESTMENTS.................................................. 40
     5.9   BOND FINANCING AMOUNTS................................................................ 41
     5.10  APPLICATION OF INSURANCE AND CONDEMNATION PROCEEDS.................................... 41

6.   TIDELANDS LEASE ACCOUNT..................................................................... 41
     6.1   DEPOSITS INTO TIDELANDS LEASE ACCOUNT................................................. 41
</Table>

                                        i
<Page>

<Table>
<S>  <C>                                                                                          <C>
7.   LIMITATION OF LIABILITY..................................................................... 42
     7.1   LIMITATION OF DISBURSEMENT AGENT'S LIABILITY.......................................... 42
     7.2   LIMITATION OF INDEPENDENT CONSTRUCTION CONSULTANT'S LIABILITY......................... 43

8.   INDEMNITY AND INSURANCE..................................................................... 43

9.   TERMINATION................................................................................. 44

10.  SUBSTITUTION OR RESIGNATION OF THE DISBURSEMENT AGENT....................................... 44
     10.1  PROCEDURE............................................................................. 44
     10.2  SUCCESSOR DISBURSEMENT AGENT BY MERGER, ETC........................................... 45
     10.3  ELIGIBILITY; DISQUALIFICATION......................................................... 45
     10.4  CONSENT OF INDEPENDENT CONSTRUCTION CONSULTANT........................................ 45

11.  INDEPENDENT CONSTRUCTION CONSULTANT......................................................... 45
     11.1  REMOVAL AND FEES...................................................................... 45
     11.2  DUTIES................................................................................ 45
     11.3  ACTS OF DISBURSEMENT AGENT............................................................ 45

12.  STATEMENT OF SECURITIES ACCOUNTS............................................................ 45

13.  MISCELLANEOUS............................................................................... 46
     13.1  WAIVER................................................................................ 46
     13.2  INVALIDITY............................................................................ 46
     13.3  NO AUTHORITY.......................................................................... 46
     13.4  ASSIGNMENT............................................................................ 46
     13.5  BENEFIT............................................................................... 46
     13.6  TIME.................................................................................. 46
     13.7  ENTIRE AGREEMENT; AMENDMENTS.......................................................... 46
     13.8  NOTICES............................................................................... 46
     13.9  COUNTERPARTS.......................................................................... 48
     13.10 CAPTIONS.............................................................................. 48
     13.11 RIGHT TO CONSULT COUNSEL.............................................................. 48
     13.12 CHOICE OF LAW......................................................................... 48
     13.13 DESIGNATION OF APPLICABLE COURTS AND JURISDICTIONS.................................... 48
     13.14 SURETYSHIP WAIVERS.................................................................... 49
</Table>

                                       ii
<Page>

                                TABLE OF EXHIBITS

EXHIBIT

A          Initial Disbursements Certificate

B-1        Form of Issuer's Closing Certification

B-2        Form of Trustee's Closing Certification

C-1        Construction Disbursement Request

C-2        Pre-Opening Disbursement Request

C-3        Form of Advance Construction Disbursement Request Certificate

C-4        Form of Interest Reserve Account Disbursement Certificate

C-5        Form of Interest Reserve Excess Transfer Certificate

C-6        Form of Tidelands Lease Certificate

D-1        Form of Available Construction Funds Certificate

D-2        Form of Project Cost Schedule Certificate

D-3        Finishes Line-Items and Amounts (from Initial Project Budget)

E          Form of Project Budget Amendment Certificate

F          Construction Contract Amendment Certificate

G-1        Form of Issuer's Initial Operating Date Disbursement Request
           Certificate

G-2        Form of Certificate of Objection of General Contractor to Issuer's
           Initial Operating Date Disbursement Request Certificate

G-3        Form of Issuer's Final Disbursement Request Certificate

G-4        Form of Tidelands Lease Disbursement Certificate

H-1        Long Form of Consent to Security Assignment of Construction
           Contract (Contracts Over $1,000,000)

H-2        Short Form of Consent to Security Assignment of Construction
           Contract (Contracts Between $500,000 and $1,000,000)

                                       iii
<Page>

                                TABLE OF EXHIBITS

EXHIBIT

I          Initial Project Budget

J          Form of Final Plans Amendment Certificate

K          Form of Additional Construction Contract Certificate

L          Permitted Encumbrances

M-1        Form of Interim Lien Affidavit (Owner)

M-2        Form of Interim Lien Affidavit (General Contractor)

M-3        Form of Interim Lien Affidavit (Other Contractor)

M-4        Form of Final Lien Affidavit (Owner)

M-5        Form of Final Lien Affidavit (General Contractor)

M-6        Form of Final Lien Affidavit (Other Contractors)

N-1        Form of Commitment to Issue Update Endorsement

N-2        Form of Separate Tax Lot Endorsement

                                       iv

\<Page>

                   CASH COLLATERAL AND DISBURSEMENT AGREEMENT

THIS CASH COLLATERAL AND DISBURSEMENT AGREEMENT (as amended, supplemented,
restated or otherwise modified from time to time, this "AGREEMENT") is dated as
of January 23, 2004, by and among U.S. BANK NATIONAL ASSOCIATION, a national
banking association, as disbursement agent, securities intermediary and
depositary bank (together with any successor disbursement agent permitted
hereunder, the "DISBURSEMENT AGENT"), U.S. BANK NATIONAL ASSOCIATION, a national
banking association, as trustee under the Indenture (as defined below) (together
with its successors and assigns from time to time under the Indenture, the
"TRUSTEE"), PROFESSIONAL ASSOCIATES CONSTRUCTION SERVICES, INC., a California
corporation (the "INDEPENDENT CONSTRUCTION CONSULTANT"), PREMIER ENTERTAINMENT
BILOXI LLC (d/b/a Hard Rock Hotel & Casino Biloxi), a Delaware limited liability
company (successor in interest by merger with Premier Entertainment, LLC, a
Mississippi limited liability company ("PREMIER"), and PREMIER FINANCE BILOXI
CORP., a Delaware corporation ("PFC," jointly and severally with Premier, the
"ISSUER"). Defined terms used herein have the meanings specified in SECTION 1.

                                    RECITALS

    A.    FACILITY. Premier desires to develop, construct and operate the Hard
Rock Hotel and Casino Biloxi, a full service gaming, hotel and entertainment
resort and certain related amenities (the "FACILITY") to be developed upon
approximately 8.5 acres along the Mississippi Gulf Coast in Biloxi, Mississippi.

    B.    FIRST MORTGAGE NOTES. Concurrently herewith, the Issuer is issuing
$160,000,000 aggregate principal amount of its 10 3/4% First Mortgage Notes due
2012 (together with all notes issued under the Indenture, including all notes
issued in exchange or replacement therefore, the "FIRST MORTGAGE NOTES"),
pursuant to the Indenture to finance Project Costs.

    C.    JUNIOR SUBORDINATED NOTE. Concurrently herewith, Rank America, Inc.
("RANK") shall purchase from the Issuer an unsecured subordinated note in an
amount of $10,000,000, the proceeds of which will be applied to finance Project
Costs, as more particularly described herein and in the Junior Subordinated Note
Investment Agreement (as defined herein).

    D.    INTERCREDITOR AGREEMENT. Concurrently herewith, the Trustee (acting on
behalf of itself and the Noteholders) and Rank have entered into an
Intercreditor Agreement, pursuant to each of which the parties thereto have set
forth certain intercreditor provisions, including the priority of the liens, the
method of decision making, the arrangements applicable to actions in respect of
approval rights and waivers, the limitations on rights of enforcement upon
default and the application of proceeds upon enforcement.

    E.    FF&E FINANCING. Premier intends to finance the costs of acquiring and
installing Additional Funding FF&E by issuing additional First Mortgage Notes
("ADDITIONAL NOTES") or by entering into agreements with respect to the FF&E
Financing pursuant to which Premier will obtain certain loans to finance
acquisition and installation costs of Additional Funding FF&E, as more
particularly described in the Indenture.

<Page>

    F.    MBFC BOND FINANCING. Premier intends to finance the costs of
acquiring, constructing and installing certain land-based improvements and
equipment with the proceeds of industrial development bonds (the "BONDS") issued
by the Mississippi Business Finance Corporation (the "MBFC") pursuant to Code
SECTION 57-10-201 et seq. (the "IDB ACT"). PFC will purchase the Bonds issued by
MBFC using equity contributions made by Premier to PFC and funded by
disbursements made from the Construction Disbursement Account (as defined below)
under this Agreement. The proceeds of the Bonds sold to PFC will be used by MBFC
to make certain loans to Premier to pay certain Project Costs incurred in
connection with such land-based improvements and equipment. This financing
transaction, as more particularly described herein and in the Bond Financing
Documents, is referred to herein as the "BOND FINANCING."

    G.    INITIAL EQUITY CONTRIBUTION. Concurrently herewith, $[33,665,245.43]
of equity shall be irrevocably and unconditionally contributed to Premier and
deposited into the Construction Disbursement Account.

    H.    USE OF PROCEEDS. The net proceeds from the issuance of the First
Mortgage Notes and the proceeds of the Junior Subordinated Note (collectively,
the "PROCEEDS"), together with the initial and any additional equity provided by
the Issuer or its Affiliates, will be used to pay Project Costs and to initially
fund the Tidelands Lease Account. The proceeds of the Bond Financing will be
used to pay Project Costs.

    I.    ACCOUNTS. $33,100,000.00 of the Proceeds will be deposited
contemporaneously with the execution of this Agreement into the Interest Reserve
Account. $1,031,900.00 of the Proceeds will be deposited contemporaneously with
the execution of this Agreement into the Tidelands Lease Account. The remaining
Proceeds (in the amount of $128,962,500.00) and an initial equity contribution
in the amount of $15,180,809.71 will be deposited contemporaneously with the
execution of this Agreement into the Construction Disbursement Account. The PFC
Payment Account will be established contemporaneously with the execution of this
Agreement to facilitate the Bond Financing. Assets maintained in the
Construction Disbursement Account and the Tidelands Lease Account and the
Interest Reserve Account are owned beneficially by Premier, subject to the terms
and conditions of this Agreement. The assets maintained in the PFC Payment
Account are owned beneficially by PFC, subject to the terms and conditions of
this Agreement.

    J.    PURPOSE. The parties have entered into this Agreement in order to set
forth the conditions upon which, and the manner in which funds will be disbursed
(a) from the Construction Disbursement Account, the Issuer's Payment Account and
the PFC Payment Account in order to permit Premier to design, develop, equip,
construct, operate and open the Facility, (b) from the Interest Reserve Account
for payment of interest due on the First Mortgage Notes, and (c) from the
Tidelands Lease Account to pay the rent and additional rent provided for under
the Tidelands Lease.

                                        2
<Page>

                                    AGREEMENT

          NOW, THEREFORE, for good and valuable consideration, the receipt and
sufficiency of which are hereby acknowledged, the parties hereto agree as
follows:

    1.  DEFINITIONS.

          1.1    DEFINED TERMS. The terms defined in this SECTION 1 shall have
the meanings herein specified:

          "ADDITIONAL FUNDING FF&E" means FF&E which Premier reasonably expects
to fund through the FF&E Financing or the issuance of Additional Notes.

          "ADDITIONAL NOTES FF&E" means the FF&E that is financed through the
issuance of additional First Mortgage Notes pursuant to this Agreement.

          "ADDITIONAL PRE-OPERATING REVENUE" means revenue generated by Premier
after the date hereof (including the net proceeds of the issuance of any
Additional Notes), other than from disposition of its assets, but only to the
extent that such revenue (a) has been deposited in the Construction Period
Accounts and (b) (i) has been disbursed from the Construction Disbursement
Account or (ii) is held by Premier, free and clear of any claims of any other
Person whatsoever; PROVIDED, HOWEVER, that as of any date of measurement,
Additional Pre-Operating Revenue shall also include without duplication:

          (x) Anticipated Investment Income; and

          (y) the lesser of (A) the net amount of FF&E Financing that the Issuer
has obtained or reasonably expects to obtain, or the amount of net proceeds of
Additional Notes that the Issuer has issued or expects to issue, in accordance
with the Indenture to fund the costs of procuring Additional Funding FF&E and
(B) the aggregate amount of Remaining Costs allocated to the "FF&E", "owner
supplied FF&E," "systems" or "gaming equipment" line items in the Project Budget
which has not yet been expended.

          "ADVANCE CONSTRUCTION DISBURSEMENT" means a disbursement from the
Construction Disbursement Account pursuant to SECTION 4.3.

          "AFFILIATE" has the meaning ascribed thereto in the Indenture.

          "AGREED PERMITS" has the meaning ascribed thereto in EXHIBIT B-1
attached hereto.

          "ANTICIPATED INVESTMENT INCOME" means, at any time, with respect to
the Construction Disbursement Account and the Issuer's Payment Account, the
amount of investment income which the Issuer reasonably determines will accrue
on the funds in each such account through the anticipated Initial Operating
Date, taking into account the current and future anticipated rates of return on
investments in each such account permitted under the Indenture and the
anticipated times and amounts of draws from each such account for the payment of
Project Costs.

                                        3
<Page>

          "APPLICABLE PERMITS" means national, state and local license
authorizations, certifications, filings, recordings, permits or other approvals
with or of any governmental authority, including, without limitation,
environmental, construction, operating or occupancy permits and any agreements,
consents or approvals that are required or that are otherwise necessary for the
performance of the design, construction, operation or maintenance of the
Facility. Without limiting the foregoing, Applicable Permits also include
Construction Period permits for temporary construction utilities and temporary
sanitary facilities, dump permits, road use permits, permits related to the use,
storage and disposal of Hazardous Materials introduced to the Site for or in
connection with the performance of the design, construction, operation or
maintenance of the Facility, and permits issued pursuant to any building,
mechanical, electrical, plumbing or similar codes.

          "ARCHITECT" means Paul Steelman, Ltd. and its successors identified by
notice from the Issuer to the Disbursement Agent.

          "ARCHITECTURAL SERVICES AGREEMENT" means that certain Owner-Architect
Agreement dated as of November 21, 2003 between Premier and Architect.

          "AVAILABLE ADVANCE CONSTRUCTION DISBURSEMENT AMOUNT" means (a) (i)
prior to June 1, 2004, the amount of $1,000,000; (ii) on or after June 1, 2004
through August 31, 2004, the amount of $3,000,000; and (iii) on or after
September 1, 2004, the amount of $5,000,000; MINUS (b) the aggregate amount then
outstanding with respect to all Advance Construction Disbursements submitted
under SECTION 4.3 which (i) have not been documented, as required in this
Agreement for other Construction Disbursements, or (ii) in the case of
Disbursements to fund Disputed Amounts under SECTION 4.3(b), which have not been
finally settled with the applicable Contractor.

          "AVAILABLE CONSTRUCTION FUNDS" means, subject to SECTION 5.4.1 with
respect to the Issuer at any given time, the sum of (a) the Original
Construction Allocation, (b) any additional equity, Loss Proceeds or other
additional amounts then on deposit in the Construction Disbursement Account
(excluding the Original Construction Allocation) and (c) all Additional
Pre-Operating Revenue as of such time, all less the sum of (x) the proceeds of
FF&E Financing that the Issuer has theretofore expended in connection with the
Facility and (y) the amount of disbursements theretofore made from the
Construction Disbursement Account.

          "BANKRUPTCY LAW" means Title 11, U.S. Code or any similar federal or
state law for the relief of debtors.

          "BARGE CONSTRUCTION CONTRACT" means that certain construction contract
to be entered into by General Contractor and a subcontractor in accordance with
SECTION 4.24 of the Indenture providing for the construction of two barges (upon
which the casino portion of the Facility will be built).

          "BOND FINANCING DOCUMENTS" shall mean the Bond Purchase Contract, the
Bond Loan Agreement, the Bond Indenture, the Bonds, the Series 2004 Note, and
the other related documents or instruments that are entered into among PFC,
Premier, and the Bond Trustee in connection with the Bond Financing.

                                        4
<Page>

          "BOND INDENTURE" means that certain Trust Indenture to be entered into
by the Bond Trustee and the Mississippi Business Finance Corporation
substantially in the form of Exhibit H to the Indenture.

          "BOND LOAN AGREEMENT" means that certain Loan Agreement to be entered
into by Premier and the Mississippi Business Finance Corporation substantially
in the form of Exhibit I to the Indenture.

          "BOND PURCHASE CONTRACT" means that certain Bond Purchase Contract to
be entered into by PFC, Premier and the Mississippi Business Finance Corporation
substantially in the form of Exhibit J to the Indenture.

          "BOND REQUISITION" shall mean the requisition substantially in the
form attached as Exhibit D to the Bond Loan Agreement.

          "BOND TRUSTEE" shall have the meaning assigned to the term "Trustee"
in the Bond Indenture.

          "BOND TRUSTEE'S CONSTRUCTION DISBURSEMENT ACCOUNT" shall mean the
"Trustee Disbursement Account" of "Construction Fund" established under SECTION
5.01 of the Bond Indenture at a bank reasonably acceptable to the Disbursement
Agent.

          "BUSINESS DAY" has the meaning ascribed thereto in the Indenture.

          "CASH EQUIVALENTS" has the meaning ascribed thereto in the Indenture.

          "COLLATERAL" means all of the following:

                 (a)     the Securities Accounts;

                 (b)     all cash, Cash Equivalents, instruments, investments
and other securities or Financial Assets at any time on deposit in or credited
to the Securities Accounts;

                 (c)     the Issuer's Payment Account;

                 (d)     the PFC Payment Account;

                 (e)     the Bonds;

                 (f)     any other collateral under any of the Collateral
Documents; and

                 (g)     all proceeds of any of the foregoing;

          "COLLATERAL DOCUMENTS" has the meaning ascribed thereto in the
Indenture.

          "COMPANY'S DIRECT DISBURSEMENT ACCOUNT" shall mean the "Company's
Direct Disbursement Account" established under SECTION 5.01 of the Bond
Indenture at a bank reasonably acceptable to the Disbursement Agent.

                                        5
<Page>

          "CONSTRUCTION CONTRACT AMENDMENT" means any material amendment or
modification of a Construction Contract (including, without limitation, any
material change order or any material owner construction change directive to a
Construction Contract).

          "CONSTRUCTION CONTRACTS" means the direct contracts between Premier
and any Person pertaining to the construction of the Facility, including the GMP
Contract and the Architectural Services Agreement.

          "CONSTRUCTION DISBURSEMENT REQUEST DATE" shall mean each date the
Issuer requests that the Disbursement Agent make a Disbursement pursuant to a
Construction Disbursement Request.

          "CONSTRUCTION EXPENSES" means Project Costs incurred in accordance
with the Project Budget, excluding, however, (a) any Pre-Issuance Expenses, (b)
any Pre-Opening Expenses and (c) any Debt Financing Costs.

          "CONSTRUCTION PERIOD" means the period from the Issuance Date
continuing until all of the funds on deposit in the Construction Period Accounts
are disbursed pursuant to SECTION 4.7.

          "CONSTRUCTION SCHEDULE" means a schedule describing the sequencing of
the components of work to be undertaken in connection with the Facility, which
schedule (as the same may be amended) demonstrates that the Initial Operating
Date will occur on or before the Operating Deadline.

          "CONTRACTOR" means a contractor or supplier of materials, fixtures,
equipment or services in connection with the construction of the Facility
pursuant to a direct contract or purchase order with Premier, including the
General Contractor and each counterparty to a contract or purchase order for a
"Direct Purchase Item" as defined in the GMP Contract.

          "DEBT FINANCING COSTS" means all payments of principal, interest,
premium (if any), and other amounts payable by the Issuer from time to time
under the Indenture, and any other senior debt or subordinated debt, if any,
incurred in accordance with the terms of the Indenture.

          "DEEDS OF TRUST" means, collectively, (a) that certain Construction
Deed of Trust, Leasehold Deed of Trust and Fixture Filing, with Assignment of
Leases and Rents dated on or about the date hereof with respect to the Site
entered into by Premier, as Trustor, Stratton Bull, as Real Estate Trustee, and
Trustee, as Beneficiary; and (b) that certain Ship Mortgage with respect to the
barge casino to be entered into by Premier, as Grantor, and Trustee, as
Beneficiary.

          "DEFAULT" means any event that is, or with the passage of time or the
giving of notice or both would be, an Event of Default.

          "DISBURSEMENT" means (a) a release of funds from the Construction
Disbursement Account to the Issuer's Payment Account or directly to any
Contractor or to Premier to pay Project Costs; (b) a release of funds from the
Construction Disbursement Account to the PFC Payment Account to enable PFC to
purchase Bonds as permitted under SECTIONS 4.2.1(b); (c) a release of funds from
the Interest Reserve Account to pay Debt Financing

                                        6
<Page>

Costs on the First Mortgage Notes as provided in SECTION 4.4(a); or (d) a
release of funds from the Tidelands Lease Account as provided in SECTION 4.8; in
each case, made pursuant to Article 4 of the Disbursement Agreement and the
Indenture.

          "DISPUTED AMOUNTS" means payments for work, services or materials
which are being disputed in good faith by the Issuer under the Construction
Contracts so long as (1) such disputes do not involve any substantial danger of
the sale, forfeiture or loss of the Facility or the Collateral, title thereto or
any interest therein and shall not interfere in any material respect with the
construction or operation of the Facility; (2) adequate cash reserves have been
provided therefor (except to the extent of any Advance Construction Disbursement
that has been Disbursed to the Title Insurer, to the General Contractor, or to
an escrow agent pursuant to SECTIONS 12.1 or 13.9 of the GMP Contract), to
secure Premier's obligation to pay for such work, services or materials, in each
case, through an allocation in the cost report attached as Schedule 1 to the
most recent Construction Disbursement Request; and (3) sufficient funds remain
available under the applicable line item in the Project Budget to pay such
disputed amount in full should Premier be obligated to make such payment under
the terms of the applicable Construction Contract.

          "EVENT OF DEFAULT" means the occurrence of any of the following
specified events:

                 (a)     the occurrence and existence of an "Event of Default"
under the Indenture; and

                 (b)     the failure of the Issuer to deliver any documents
required to be delivered by the Issuer pursuant to this Agreement and any such
failure continues for 30 days after written notice thereof without being cured.

          "EVENT OF LOSS" has the meaning ascribed thereto in the Indenture.

          "EVENT OF LOSS OFFER" has the meaning ascribed thereto in the
Indenture.

          "FF&E" means furniture, fixtures and equipment that is or will be
installed in the Facility.

          "FF&E COLLATERAL" means FF&E in respect of which the lenders under the
FF&E Financing have advanced funds and which are not subject to a Lien in favor
of the Trustee in accordance SECTION 4.09 of the Indenture.

          "FF&E FINANCING" has the meaning ascribed thereto in the Indenture.

          "FINAL PLANS" means, with respect to any particular work or
improvement that constitutes a portion of the Facility:

                 (a)     the Plans for such work or improvement, if any, that
are described on EXHIBIT 5 to the Issuer's Closing Certification; and

                                        7
<Page>

                 (b)     to the extent Plans for such work or improvement are
not described on EXHIBIT 5 to the Issuer's Closing Certification, the Plans for
such work or improvement to the extent such Plans:

                         (i)    have received all approvals from all
governmental authorities required to approve such Plans that are necessary to
commence construction of such work or improvements, if any;

                         (ii)   contain sufficient specificity to permit the
completion of such work or improvement;

                         (iii)  are consistent with constructing the Facility to
include the Minimum Facilities;

                         (iv)   have been signed by an architect licensed to
practice architecture in the State of Mississippi;

                         (v)    call for construction of the Facility in a
manner consistent with the Initial Operating Date occurring on or prior to the
Operating Deadline;

PROVIDED, HOWEVER, that the Final Plans may be modified from time to time in
accordance with the terms hereof.

          "FINAL PLANS AMENDMENT CERTIFICATE" means an Officer's Certificate
from the Issuer in the form attached hereto as EXHIBIT J, together with the
General Contractor's, Independent Construction Consultant's and Architect's
certificates as provided in EXHIBITS 1, 2 AND 3 and attached thereto.

          "FINISHES" means the following Hard Costs with respect to the
Facility: flooring, bathroom fixtures and accessories, decorative metals,
decorative light fixtures and mill work, countertops, artwork, mirrors, water
and other special effects, paint, ceiling finishes and wall coverings, all of
which items are included in the line items set forth on EXHIBIT D-3 attached
hereto.

          "FIRST MORTGAGE NOTE OBLIGATIONS" means any principal, interest,
premium (if any), liquidated damages (if any), penalties, fees, indemnification,
reimbursements, damages and other liabilities payable with respect to the First
Mortgage Notes pursuant to the Indenture and any other obligations of the Issuer
pursuant to the Indenture or the Collateral Documents.

          "GENERAL CONTRACTOR" means Roy Anderson Corp, a Mississippi
corporation.

          "GMP CONTRACT" means that certain Owner-Contractor Agreement dated as
of December 24, 2003 between Premier and the General Contractor, as amended by
that certain First Amendment to Agreement between Owner and Contractor dated as
of January 22, 2004.

          "GOVERNMENT SECURITIES" has the meaning ascribed thereto in the
Indenture.

          "GOVERNMENTAL ACTION" means any resolution, ordinance, statute,
regulation, order or decision regardless of how constituted having the force of
law.

                                        8
<Page>

          "HARD COSTS" means the costs and expenses in respect of supplying
goods, materials and labor for the construction of improvements relating to the
Facility or other amounts payable pursuant to a Construction Contract,
including, among other things, the Permitted Land-Based Project Costs.

          "INDENTURE" means the Indenture dated as of the date hereof, among the
Issuer and the Trustee, relating to the First Mortgage Notes (as the same may be
amended, modified or supplemented from time to time).

          "INDEPENDENT CONSTRUCTION CONSULTANT" means Professional Associates
Construction Services, Inc. and its successors and replacements, as designated
by the Trustee.

          "INDEPENDENT CONSTRUCTION CONSULTANT'S ENGAGEMENT AGREEMENT" means
that certain Professional Services Agreement dated October 30, 2003 between the
Independent Construction Consultant and the Issuer.

          "INITIAL DISBURSEMENTS CERTIFICATE" means the Officer's Certificate
signed by Premier on behalf of the Issuer in the form attached hereto as EXHIBIT
A.

          "INITIAL OPERATING DATE" has the meaning ascribed thereto in the
Indenture.

          "INITIAL PROJECT BUDGET" means the itemized schedules setting forth on
a line item basis all of the estimated Project Costs attached hereto as EXHIBIT
I (except that the Initial Project Budget shall not include the Issuance Fees
and Expenses).

          "INTERCREDITOR AGREEMENT" has the meaning ascribed thereto in the
Indenture.

          "INTEREST PAYMENT DATE" has the meaning ascribed thereto in the
Indenture.

          "ISSUANCE DATE" means the date of the Indenture.

          "ISSUANCE FEES AND EXPENSES" means fees and expenses (a) incurred by
the Issuer or AA Capital Equity Fund, L.P. (one of its members), in connection
with the raising of debt to finance the Facility that is evidenced by the First
Mortgage Notes and the Junior Subordinated Note and (b) paid on or before the
Issuance Date. The Issuance Fees and Expenses are identified on EXHIBIT 1 to the
Issuer's Closing Certification as "Transaction Fees and Expenses."

          "ISSUER'S CLOSING CERTIFICATION" means an Officer's Certificate signed
by Premier on behalf of the Issuer in the form attached hereto as EXHIBIT B-1.

          "ISSUING AGENT" means Balch & Bingham, LLP, in its capacity as issuing
agent for the Title Company, together with any successor issuing agent
designated from time to time by the Title Company in a written notice to the
Disbursement Agent.

          "JUNIOR SUBORDINATED NOTE" means that certain $10,000,000 junior
subordinated unsecured note evidencing the unsecured subordinated loans made by
Rank to the Issuer under the Junior Subordinated Note Investment Agreement.

                                        9
<Page>

          "JUNIOR SUBORDINATED NOTE INVESTMENT AGREEMENT" means that certain
Investment Agreement dated as of January 13, 2004, entered into among the Issuer
and Rank.

          "KNOWLEDGE" of the Issuer, the Trustee, the Disbursement Agent, the
Architect, the General Contractor or the Independent Construction Consultant,
means the actual knowledge of any officer, director or management employee of
such Person.

          "LIEN" has the meaning ascribed thereto in the Indenture.

          "MATERIAL CONSTRUCTION CONTRACT" means each Construction Contract
identified by the Issuer to be material to the Facility (which the Issuer agrees
shall include the GMP Contract and all other Construction Contracts with an
individual contract amount in excess of $500,000).

          "MINIMUM FACILITIES" means, with respect to the Hard Rock Hotel &
Casino Biloxi, a casino with at least 1,350 slot machines and 45 table games, a
hotel with at least 275 hotel rooms, three restaurants with seating for at least
1,000 people (including, without limitation, a Hard Rock Cafe), three bars
(including, without limitation, the rooftop bar), a 900 person capacity Hard
Rock Live! branded entertainment venue and a parking structure for at least 1440
vehicles.

          "NEW YORK UCC" means the Uniform Commercial Code as the same may, from
time to time, be in effect in the State of New York.

          "NOTEHOLDERS" means holders from time to time of the First Mortgage
Notes.

          "OFFICER'S CERTIFICATE" means: (i) prior to the Initial Operating
Date, a certificate of Premier signed by one officer of Premier who must be the
principal executive officer, the principal financial officer, the treasurer or
the principal accounting officer of Premier; and (ii) on or after the Initial
Operating Date, a certificate of Premier signed by two officers of Premier, one
of whom must be the principal executive officer, the principal financial
officer, the treasurer or the principal accounting officer of Premier; PROVIDED,
HOWEVER that if amounts are requested to be Disbursed to the PFC Payment
Account, such certificate must also be signed by one officer of PFC whom must be
the principal executive officer, the principal financial officer, the treasurer
or the principal accounting officer of PFC.

          "OPERATING" has the meaning ascribed thereto in the Indenture.

          "OPERATING PERIOD" means the period commencing on the Initial
Operating Date of the Facility and continuing until the date of termination of
this Agreement under SECTION 8.

          "OPERATING DEADLINE" means December 31, 2005.

          "ORIGINAL CONSTRUCTION ALLOCATION" means: (a) the total amount of the
Proceeds plus (b) the initial equity that is deposited into the Construction
Disbursement Account pursuant to SECTION 4.1(b), LESS (w) the Initial
Disbursements listed in Paragraphs (a) through (o) of the Initial Disbursements
Certificate, (x) the difference of (i) the portion of the Proceeds that has been
deposited into the Interest Reserve Account LESS (ii) the portion of such
Proceeds that is transferred into the Construction Disbursement Account pursuant
to SECTION 4.4(b), and (y) the

                                       10
<Page>

$1,031,900 deposited in the Tidelands Lease Account pursuant to SECTION 6.1, and
(z) to the extent not otherwise excluded from the definition of "Proceeds", the
Issuance Fees and Expenses.

          "OTHER PROJECT COSTS" shall mean all Project Costs (other than the
Permitted Land-Based Project Costs).

          "PERMITTED ENCUMBRANCES" means the exceptions set forth on EXHIBIT L
and a standard A.L.T.A. exception for mechanics liens; provided that any
mechanic's or materialman's lien that has actually been filed or recorded shall
not constitute a Permitted Encumbrance.

          "PERMITTED AMOUNTS" means, without duplication, (a) uncompleted
Punchlist Items with an aggregate Punchlist Completion Amount (as reasonably
determined by the Independent Construction Consultant) of less than $800,000;
(b) Disputed Amounts with an aggregate value (as reasonably determined by the
Independent Construction Consultant) of less than $2,000,000; and (c) the
Retainage Amounts with an aggregate value (as reasonably determined by the
Independent Construction Consultant) of less than $5,000,000.

          "PERMITTED LAND-BASED PROJECT COSTS" shall mean those Project Costs in
the aggregate amount not to exceed $60,000,000 that constitute "Costs" (as such
term is defined in the Bond Loan Agreement) permitted to be financed with the
proceeds of the Bonds pursuant to the Bond Financing Documents.

          "PERMITTED LIENS" has the meaning ascribed thereto in the Indenture.

          "PERSON" has the meaning ascribed thereto in the Indenture.

          "PFC" means Premier Finance Biloxi Corp., a Delaware corporation.

          "PLANS" means all drawings, plans and specifications prepared by or on
behalf of Premier, as amended or supplemented from time to time in accordance
with this Agreement, and, if required, submitted to and approved by the
appropriate regulatory authorities, which describe and show the Facility and the
labor and materials necessary for the construction thereof.

          "PLEDGE AND SECURITY AGREEMENT" means that certain Pledge and Security
Agreement dated as of the date hereof, among Premier, PFC and the Trustee, for
the benefit of the Noteholders (as the same may be amended, modified or
supplemented from time to time).

          "PRE-ISSUANCE EXPENSES" means, collectively, (a) any expenses paid by
the Issuer or AA Capital Equity Fund, L.P. (one of its members), in connection
with the Facility prior to the Issuance Date, and (b) to the extent not included
within clause (a), any expenses paid pursuant to Paragraphs (a) through (o) of
the Initial Disbursements Certificate.

          "PRELIMINARY PLANS" means, with respect to any particular work or
improvement, the Plans for such work or improvement, if any, that are described
on EXHIBIT 4 to the Issuer's Closing Certification.

          "PRE-OPENING EXPENSES" means expenses of the Issuer related to the
preparation of the Facility for opening and operation (other than expenses
directly related to the construction

                                       11
<Page>

of the Facility) to be incurred prior to the Initial Operating Date as set forth
in the Project Budget, excluding, however, (i) any Debt Financing Costs and (ii)
any Pre-Issuance Expenses (except Pre-Opening Expenses may include
$804,039 of Pre-Issuance Expenses).

          "PROJECT BUDGET" means the Initial Project Budget as the Initial
Project Budget may be amended from time to time in accordance with this
Agreement.

          "PROJECT COST SCHEDULE" means an itemized schedule in the form
attached as SCHEDULE 1 to EXHIBIT D-2 hereto.

          "PROJECT COSTS" means the costs to be incurred in connection with the
acquisition, financing, design, development, construction, equipping and opening
of the Facility, including all Construction Expenses, Debt Financing Costs and
Pre-Opening Expenses.

          "PUNCHLIST COMPLETION AMOUNT" means, from time to time from and after
the Initial Operating Date, the estimated cost to complete all remaining
Punchlist Items if the owner of the Facility were to engage independent,
reputable and appropriately experienced and licensed contractor(s) to complete
such work and no other work (certified by the Issuer and the Independent
Construction Consultant with respect to each Disbursement from and after the
Initial Operating Date in their respective certificates in the form of EXHIBIT
C-1 and EXHIBIT 2 TO EXHIBIT C-1).

          "PUNCHLIST ITEMS" means minor or insubstantial details of construction
or mechanical adjustment, the non-completion of which, when all such items are
taken together, will not interfere in any material respect with the use or
occupancy of the Facility for its intended purposes or the ability of the owner
or lessee, as applicable, of any portion of the Facility (or any tenant thereof)
to perform work that is necessary or desirable to prepare such portion of the
Facility for such use or occupancy; PROVIDED that, in all events, "Punchlist
Items" shall include (to the extent not already completed), without limitation,
the items set forth in the punchlist to be delivered by the General Contractor
in connection with "Substantial Completion" under the GMP Contract and all items
that are listed on the "punchlists" furnished by the Harrison County Building
Department, the Mississippi Department of Transportation or the Harrison County
Department of Public Works in connection with, or after, the issuance of the
temporary certificate of occupancy as those that must be completed in order for
the Harrison County Building Department to issue a permanent certificate of
occupancy for the Facility.

          "REALIZED SAVINGS" means, with respect to any line item in the Project
Budget, the excess of the Remaining Budgeted Amount for such line item over the
amount of funds expended or to be expended by the Issuer after the Issuance Date
to complete the tasks set forth in such line item and for the materials and
services used to complete such tasks; PROVIDED, HOWEVER, that Realized Savings
for any line item shall be deemed to be zero unless and until the Issuer has
delivered an executed Project Budget Amendment Certificate (together with all
exhibits thereto) which includes such Realized Savings; PROVIDED, FURTHER, that
no Realized Savings shall be obtainable with respect to the "working capital and
machine loads" or "contingency" line items under the Project Budget; PROVIDED,
STILL FURTHER, that the Realized Savings for the "GMP Contract" line item shall
be deemed to be zero until all work or improvements contemplated by such line
item are not subject to any allowances under the GMP

                                       12
<Page>

Contract and Final Plans have been completed with respect to such work or
improvements as evidenced by a Final Plans Amendment Certificate delivered in
accordance with SECTION 5.6.

          "REGISTRATION RIGHTS AGREEMENT" has the meaning ascribed thereto in
the Indenture.

          "REMAINING BUDGETED AMOUNT" for any line item on the Project Budget
means the Total Budgeted Amount for such line item in the Project Budget less
the amount of Pre-Issuance Expenses with respect to such line item.

          "REMAINING COSTS" means, at any given time, the amount of Construction
Expenses (including Retainage Amounts) and Pre-Opening Expenses set forth in the
Project Budget that remain unpaid at such time (including amounts that have not
yet accrued at such time).

          "RETAINAGE AMOUNTS" means, at any given time, amounts that have
accrued and are owing under the terms of a Construction Contract for work or
services to the Issuer already provided but which at such time (in accordance
with the terms of the Construction Contract) are being withheld from payment to
the Contractor thereunder until certain subsequent events (e.g., completion
benchmarks) have been achieved.

          "SECURITIES ACCOUNTS" means the Construction Period Accounts and the
Tidelands Lease Account, each as defined in SECTION 2.2.

          "SERIES 2004 NOTE" shall have the meaning assigned to the term "Series
2004 Note" in the Bond Indenture.

          "SHIP MORTGAGE" means that certain First Preferred Ship Mortgage dated
as of the date hereof, between Premier and the Trustee.

          "SOFT COSTS" means all costs and expenses (other than Hard Costs) set
forth in the Project Budget, including, without limitation, Pre-Opening
Expenses.

          "TIDELANDS LEASE" means that certain Public Trust Tidelands Lease
dated as of October 27, 2003 between Premier and the Secretary of State, with
the approval of the Governor, for and on behalf of the State of Mississippi.

          "TIDELANDS LEASE REQUIRED PAYMENT AMOUNT" means, as of any time of
calculation, the total amount of money (including rent) that Premier reasonably
anticipates will be due and owing to the State of Mississippi under the
Tidelands Lease during the 60 days immediately following the date of
calculation.

          "TIDELANDS LEASE SHORTAGE AMOUNT" means, as of any time of
calculation, the excess of the Tidelands Lease Required Payment Amount over the
balance then on deposit in the Tidelands Lease Account.

          "TITLE INSURER" means First American Title Insurance Company.

                                       13
<Page>

          "TOTAL BUDGETED AMOUNT" with respect to any line item in the Project
Budget at any given time means the total amount budgeted for such line item in
the Project Budget at such time.

          "TRANSACTION DOCUMENTS" means each of this Agreement, the Indenture,
the First Mortgage Notes, the Registration Rights Agreement, the Junior
Subordinated Note Investment Agreement, the Pledge and Security Agreement, the
Deeds of Trust, each other Collateral Document, the Construction Contracts, the
Bond Financing Documents, the Hard Rock Cafe Lease, the Hard Rock License
Agreement, the Hard Rock Memorabilia Lease, the Hard Rock Retail Store Lease,
the Tidelands Lease, and the City of Biloxi Lease (each as defined in the
Indenture).

          "TRUSTEE'S CLOSING CERTIFICATE" means a closing certificate from the
Trustee in the form of EXHIBIT B-2 attached hereto.

          "TRUSTEE'S TITLE POLICIES" means: (i) the policy of title insurance
with respect to the real property issued by the Title Insurer as of the Issuance
Date as provided in SECTION 4.25 of the Indenture; and (ii) from and after the
date the Ship Mortgage is required under SECTION 4.24 of the Indenture, the
policy of title insurance with respect to the Ship Mortgage to be issued by the
Title Insurer as provided in SECTION 4.24 of the Indenture.

          "UCC" means: (a) with respect to the creation and attachment of any
security interest, the New York UCC and (b) with respect to the perfection, the
effect of perfection or non-perfection and priority of the security interest,
the Uniform Commercial Code of the jurisdiction specified by the mandatory
choice of law rules set forth in the New York UCC.

          1.2    INDEX OF ADDITIONAL DEFINED TERMS. In addition, the terms
listed in the left column below shall have the respective meanings assigned to
such terms in the Section of this Agreement listed opposite such terms in the
right column below:

<Table>
<Caption>
          DEFINED TERM                                                                SECTION
          ------------                                                                -------
          <S>                                                                   <C>
          ADDITIONAL CONSTRUCTION CONTRACT CERTIFICATE....................................5.3
          ADDITIONAL NOTES......................................................E of Recitals
          ADVANCE CONSTRUCTION DISBURSEMENT REQUEST.......................................4.3
          AGREEMENT..............................................................Introduction
          APPLICABLE COURTS.............................................................13.12
          AVAILABLE CONSTRUCTION FUNDS CERTIFICATE........................................5.4
          BOND FINANCING........................................................F of Recitals
          BONDS.................................................................F of Recitals
          CONSTRUCTION CONTRACT AMENDMENT CERTIFICATE.....................................5.2
          CONSTRUCTION DISBURSEMENT ACCOUNT.............................................2.2.1
          CONSTRUCTION DISBURSEMENT REQUEST .........................................4.2.1(a)
          CONSTRUCTION PERIOD ACCOUNTS..................................................2.2.1
          DISBURSEMENT AGENT.....................................................Introduction
          DISBURSEMENT REQUEST..........................................................4.2.1
          ENTITLEMENT ORDER...............................................................2.4
          EXPECTED INTEREST RESERVE INCOME AMOUNT......................................4.4(b)
</Table>

                                       14
<Page>

<Table>
          <S>                                                                   <C>
          FACILITY..............................................................A of Recitals
          FF&E AGENT............................................................D of Recitals
          FINANCIAL ASSETS................................................................2.4
          FIRST MORTGAGE NOTES..................................................B of Recitals
          IDB ACT...............................................................F of Recitals
          INDENTURE.............................................................A of Recitals
          INDEPENDENT CONSTRUCTION CONSULTANT....................................Introduction
          INITIAL DISBURSEMENTS...........................................................4.1
          INITIAL DISBURSEMENTS CERTIFICATE ..............................................4.1
          INITIAL INTEREST RESERVE ACCOUNT TARGET......................................4.4(b)
          INTEREST RESERVE ACCOUNT......................................................2.2.1
          INTEREST RESERVE INCOME REQUIREMENT..........................................4.4(b)
          ISSUER.................................................................Introduction
          ISSUER'S PAYMENT ACCOUNT......................................................2.2.2
          ISSUER'S PAYMENT ACCOUNT ORDER..................................................2.5
          LOSS PROCEEDS..................................................................5.10
          MATERIAL CONSTRUCTION CONTRACT AMENDMENT........................................5.2
          MBFC..................................................................F of Recitals
          OBLIGATIONS.....................................................................2.3
          OUTSTANDING RELEASES............................................................4.3
          PFC....................................................................Introduction
          PFC PAYMENT ACCOUNT...........................................................2.2.4
          PFC PAYMENT ACCOUNT ORDER.......................................................2.6
          PRE-OPENING DISBURSEMENT REQUEST..............................................4.2.1
          PREMIER................................................................Introduction
          PROCEEDS..............................................................H of Recitals
          PROJECT BUDGET AMENDMENT CERTIFICATE..........................................5.1.3
          PROJECT COST SCHEDULE CERTIFICATE...............................................5.5
          RANK..................................................................C of Recitals
          RESERVED AMOUNT.................................................................4.6
          SITE..................................................................B of Recitals
          SECURITY ENTITLEMENTS ..........................................................2.4
          TIDELANDS LEASE ACCOUNT.......................................................2.2.3
          TIDELANDS LEASE CERTIFICATE..................................................6.1(a)
          TRUSTEE................................................................Introduction
          UNINCORPORATED MATERIALS...................................................4.2.2(e)
          UPDATE ENDORSEMENT.........................................................4.2.2(d)
</Table>

    2.  APPOINTMENT OF DISBURSEMENT AGENT; ESTABLISHMENT OF SECURITIES ACCOUNTS;
RELATED PROVISIONS.

          2.1    APPOINTMENT OF THE DISBURSEMENT AGENT. The Disbursement Agent
is hereby appointed by the Issuer and the Trustee as disbursement agent
hereunder, and the Disbursement Agent hereby agrees to act as such and to accept
all cash, payments, other amounts and Cash Equivalents to be delivered to or
held by the Disbursement Agent pursuant to the terms of this Agreement. The
Disbursement Agent shall hold and safeguard the Securities Accounts , the
Issuer's Payment Account and the PFC Payment Account (and the cash, instruments
and

                                       15
<Page>

securities on deposit therein) during the term of this Agreement and shall
treat the Securities Accounts, the Issuer's Payment Account, and the PFC Payment
Account and the cash, instruments, and securities in the Securities Account, the
Issuer's Payment Account and the PFC Payment Account, as funds, instruments and
securities pledged by Premier to the Trustee for the ratable benefit of the
Noteholders to be held in accordance with the provisions hereof.

          2.2    ESTABLISHMENT OF ACCOUNTS.

                 2.2.1   ESTABLISHMENT OF CONSTRUCTION PERIOD ACCOUNTS. The
Disbursement Agent hereby establishes at its offices located at 60 Livingston
Avenue, St. Paul, MN 55107-2292, the following accounts, each of which shall be
maintained as special, segregated securities account at all times until such
accounts are closed as set forth in SECTION 4.7, unless earlier termination is
otherwise provided for herein:

<Table>
<Caption>
ACCOUNT:                                                        ACCOUNT NUMBER:
<S>                                                             <C>
Construction Disbursement Account                               744829001

Interest Reserve Account                                        744829002
</Table>

The terms set forth in the left column above, as used in this Agreement, shall
be deemed to refer to the accounts having the account numbers listed in the
right column above or any substitute account selected in accordance with the
terms of this Agreement. The Construction Disbursement Account and the Interest
Reserve Account are sometimes referred to collectively herein as the
"CONSTRUCTION PERIOD ACCOUNTS."

                 2.2.2   ESTABLISHMENT OF ISSUER'S PAYMENT ACCOUNT. The
Disbursement Agent hereby establishes at its offices located at 60 Livingston
Avenue, St. Paul, MN 55107-2292, the following special, segregated and
irrevocable collateral account for deposits and checking which shall be
maintained at all times until the termination of this Agreement, unless earlier
termination is otherwise provided for herein:

<Table>
<Caption>
ACCOUNT:                                                        ACCOUNT NUMBER:
<S>                                                             <C>
Issuer's Payment Account                                        744829003
</Table>

The term set forth in the left column above, as used in this Agreement, shall be
deemed to refer to the account having the account number listed in the right
column above or any substitute account selected in accordance with the terms of
this Agreement.

                 2.2.3   ESTABLISHMENT OF TIDELAND'S LEASE ACCOUNT. The
Disbursement Agent hereby establishes at its offices located at 60 Livingston
Avenue, St. Paul, MN 55107-2292, the following special, segregated and
irrevocable securities account which shall be maintained at all times until the
termination of this Agreement, unless earlier termination is otherwise provided
for herein:

<Table>
<Caption>
ACCOUNT:                                                        ACCOUNT NUMBER:
<S>                                                             <C>
Tidelands Lease Account                                         744829005
</Table>

                                       16
<Page>

The term set forth in the left column above, as used in this Agreement, shall be
deemed to refer to the account having the account number listed in the right
column above or any substitute account selected in accordance with the terms of
this Agreement.

                 2.2.4   ESTABLISHMENT OF PFC PAYMENT ACCOUNT. The Disbursement
Agent hereby establishes at its offices located at 60 Livingston Avenue, St.
Paul, MN 55107-2292, the following special, segregated and irrevocable
collateral account for deposits and checking with PFC as the account holder,
which shall be maintained at all times until the termination of this Agreement,
unless earlier termination is otherwise provided for herein:

<Table>
<Caption>
ACCOUNT:                                                        ACCOUNT NUMBER:
<S>                                                             <C>
PFC Payment Account                                             744829004
</Table>

The term set forth in the left column above, as used in this Agreement, shall be
deemed to refer to the account having the account number listed in the right
column above or any substitute account selected in accordance with the terms of
this Agreement.

          2.3    ACKNOWLEDGEMENT OF SECURITY INTEREST; CONTROL. Pursuant to the
Pledge and Security Agreement, in order to secure the payment and performance of
all covenants, agreements and payment and other obligations of the Issuer under
the Indenture and the Collateral Documents (the "OBLIGATIONS"), the Issuer has
pledged to and created in favor of the Trustee a security interest in and to,
the Securities Accounts, the Issuer's Payment Account, the PFC Payment Account,
all cash, Cash Equivalents, instruments, investments, securities entitlements
and other securities at any time on deposit in the Securities Accounts, the
Issuer's Payment Account, and the PFC Payment Account, and all proceeds of any
of the foregoing. All moneys, Cash Equivalents, instruments, investments and
securities at any time on deposit in any of the Securities Accounts, the
Issuer's Payment Account, or the PFC Payment Account shall constitute collateral
security for the payment and performance by the Issuer of its obligations and
shall at all times be subject to the control of the Trustee, and shall be held
in the custody of the Disbursement Agent in trust for the purposes of, and on
the terms set forth in, this Agreement.

          2.4    CONTROL OF SECURITIES ACCOUNTS. The Disbursement Agent hereby
agrees and confirms that it has established the Securities Accounts as set forth
and defined in this Agreement. The Disbursement Agent and the Issuer agree that
(a) the Disbursement Agent is acting as a "securities intermediary" (within the
meaning of SECTION 8-102(14) of the UCC) with respect to the Securities Accounts
and the "financial assets" (within the meaning of SECTION 8-102(a)(9) of the
UCC, the "FINANCIAL ASSETS") credited to the Securities Accounts; (b) each such
Securities Account established by the Disbursement Agent is and will be
maintained as a "securities account" (within the meaning of SECTION 8-501 of the
UCC); (c) the Issuer is an "entitlement holder" (within the meaning of SECTION
8-102(a)(7) of the UCC) in respect of the Financial Assets credited to such
Securities Accounts and with respect to such Securities Accounts and the
Disbursement Agent shall so note in its records pertaining to such Financial
Assets and Securities Accounts; and (d) all Financial Assets in registered form
or payable to or to the order of and credited to any such Securities Account
shall be registered in the name of,

                                       17
<Page>

payable to or to the order of, or specially endorsed to, the Disbursement Agent,
or in blank, or credited to another securities account maintained in the name of
the Disbursement Agent, as applicable, and in no case will any Financial Asset
credited to any such Securities Account be registered in the name of, payable to
or to the order of, or endorsed to, the Issuer except to the extent the
foregoing have been subsequently endorsed by the Issuer to the Disbursement
Agent or in blank. Each item of property (including a security, security
entitlement, investment property, instrument or obligation, share,
participation, interest or other property whatsoever) credited to any Securities
Account shall be treated as a Financial Asset. Until this Agreement terminates
in accordance with the terms hereof, the Trustee shall have "control" (within
the meaning of SECTION 8-106(d)(2) of the UCC) of the Issuer's "security
entitlements" (within the meaning of SECTION 8-102(a)(17) of the UCC, "SECURITY
ENTITLEMENTS") with respect to the Securities Accounts and the Financial Assets
credited to the Securities Accounts. All property delivered to the Disbursement
Agent by or on behalf of the Issuer pursuant to this Agreement will be promptly
credited to the Securities Accounts and shall be treated as Financial Assets. If
at any time the Disbursement Agent shall receive from the Trustee any
"entitlement order" (within the meaning of SECTION 8-102(8) of the UCC, an
"ENTITLEMENT ORDER") relating to the Securities Accounts or Financial Assets
credited to the Securities Accounts, the Disbursement Agent shall comply with
such Entitlement Order without further consent by the Issuer or any other
Person. In the event that the Disbursement Agent receives conflicting
Entitlement Orders relating to the Securities Accounts or Financial Assets
credited to the Securities Accounts from the Trustee and any other Person
(including, without limitation, the Issuer), the Disbursement Agent shall comply
with the Entitlement Orders originated by the Trustee. Each of the Issuer and
the Disbursement Agent agrees that it has not and will not execute and deliver,
or otherwise become bound by, any agreement under which it agrees with any
Person other than the Trustee (and, to the extent provided herein, the Issuer)
to comply with Entitlement Orders originated by such Person relating to the
Securities Accounts or Financial Assets credited to the Securities Accounts.
Except for the claims and interests of the Trustee and the Issuer in the
Securities Accounts and the Financial Assets credited to the Securities
Accounts, neither the Disbursement Agent nor the Issuer has Knowledge of any
claim to, or interest in, any Securities Account or Financial Assets credited to
the Securities Accounts. If the Disbursement Agent or the Issuer obtains
Knowledge that any Person has asserted a lien, encumbrance or adverse claim
against any of the Securities Accounts or Financial Assets credited to the
Securities Accounts, such party will promptly notify the Trustee thereof. In the
event that the Disbursement Agent has or subsequently obtains by agreement,
operation of law or otherwise a lien or security interest in any Securities
Account, any Security Entitlement carried therein or credited thereto or any
Financial Asset that is the subject of any such Security Entitlement, the
Disbursement Agent agrees that such lien or security interest shall be
subordinate to the lien and security interest of the Trustee. The Financial
Assets standing to the credit of the Securities Accounts will not be subject to
deduction, set-off, banker's lien or any other right, and the Disbursement Agent
shall not grant, permit or consent to any other right or interest in such
Financial Assets, in favor of any Person (including the Disbursement Agent)
other than the Trustee. Regardless of any provision in any other agreement, for
purposes of the UCC, the State of New York shall be deemed to be the
Disbursement Agent's jurisdiction (within the meaning of SECTION 8-110 of the
UCC). The Securities Accounts shall be governed by the laws of the State of New
York except as specified in SECTION 13.12.

          2.5    CONTROL OF ISSUER'S PAYMENT ACCOUNT. The Disbursement Agent
hereby agrees and confirms that it has established the Issuer's Payment Account
as set forth and defined

                                       18
<Page>

in this Agreement. For so long as this Agreement remains in effect, the
Disbursement Agent waives its rights of chargeback, setoff (including such right
of setoff as set forth in SECTION 9-340 of the UCC) and/or banker's lien against
the Issuer's Payment Account. Until this Agreement terminates in accordance with
the terms hereof, the Trustee shall have "control" (within the meaning of
SECTION 9-104 of the UCC) of the Issuer's Payment Account. If at any time the
Disbursement Agent shall receive from the Trustee any instruction directing
disposition of any funds in the Issuer's Payment Account (a "ISSUER'S PAYMENT
ACCOUNT ORDER"), the Disbursement Agent shall comply with such Issuer's Payment
Account Order without further consent by the Issuer or any other Person. In the
event that the Disbursement Agent receives conflicting Issuer's Payment Account
Orders relating to the Issuer's Payment Account, the Disbursement Agent shall
comply with the Issuer's Payment Account Orders originated by the Trustee. Each
of the Issuer and the Disbursement Agent agrees that it has not and will not
execute and deliver, or otherwise become bound by, any agreement under which it
agrees with any Person other than the Trustee to comply with Issuer's Payment
Account Orders originated by such Person relating to the Issuer's Payment
Account. If the Disbursement Agent or the Issuer obtains Knowledge that any
Person has asserted a lien, encumbrance or adverse claim against the Issuer's
Payment Account, such party will promptly notify the Trustee thereof. In the
event that the Disbursement Agent has or subsequently obtains by agreement,
operation of law or otherwise a lien or security interest in the Issuer's
Payment Account, the Disbursement Agent agrees that such lien or security
interest shall be subordinate to the lien and security interest of the Trustee.
Regardless of any provision in any other agreement, for purposes of the UCC, the
State of New York shall be deemed to be the Disbursement Agent's jurisdiction
(within the meaning of SECTION 9-304 of the UCC). The Issuer's Payment Account
shall be governed by the laws of the State of New York except as specified in
SECTION 13.12.

          2.6    CONTROL OF PFC PAYMENT ACCOUNT. The Disbursement Agent hereby
agrees and confirms that it has established the PFC Payment Account as set forth
and defined in this Agreement. For so long as this Agreement remains in effect,
the Disbursement Agent waives its rights of chargeback, setoff (including such
right of setoff as set forth in SECTION 9-340 of the UCC) and/or banker's lien
against the PFC Payment Account. Until this Agreement terminates in accordance
with the terms hereof, the Trustee shall have "control" (within the meaning of
SECTION 9-104 of the UCC) of the PFC Payment Account. If at any time the
Disbursement Agent shall receive from the Trustee any instruction directing
disposition of any funds in the PFC Payment Account (a "PFC PAYMENT ACCOUNT
ORDER"), the Disbursement Agent shall comply with such PFC Payment Account Order
without further consent by PFC or any other Person. In the event that the
Disbursement Agent receives conflicting PFC Payment Account Orders relating to
the PFC Payment Account, the Disbursement Agent shall comply with the PFC
Payment Account Orders originated by the Trustee. Each of PFC and the
Disbursement Agent agrees that it has not and will not execute and deliver, or
otherwise become bound by, any agreement under which it agrees with any Person
other than the Trustee to comply with PFC Payment Account Orders originated by
such Person relating to the PFC Payment Account. If the Disbursement Agent or
PFC obtains Knowledge that any Person has asserted a lien, encumbrance or
adverse claim against the PFC Payment Account, such party will promptly notify
the Trustee thereof. In the event that the Disbursement Agent has or
subsequently obtains by agreement, operation of law or otherwise a lien or
security interest in the PFC Payment Account, the Disbursement Agent agrees that
such lien or security interest shall be subordinate to the lien and security
interest of the Trustee. Regardless of any provision in any other agreement, for
purposes of the UCC, the State of New York shall be deemed to be the
Disbursement Agent's

                                       19
<Page>

jurisdiction (within the meaning of SECTION 9-304 of the UCC). The PFC Payment
Account shall be governed by the laws of the State of New York except as
specified in SECTION 13.12.

          2.7    THE ISSUER'S RIGHTS. The Issuer shall not have any rights or
powers with respect to any amounts in the Securities Accounts, the Issuer's
Payment Account, or the PFC Payment Account or any part thereof except (a) as
provided in SECTION 2.8 and (b) the right to have such amounts applied in
accordance with the provisions hereof.

          2.8    CASH EQUIVALENTS. Subject to the last sentence of this
SECTION 2.8, the Disbursement Agent shall invest any money held in any
Securities Account other than in the Interest Reserve Account, in such Cash
Equivalents, and in the case of the Interest Reserve Account, in such Government
Securities, in each case, as directed in writing by the Issuer from time to
time. In the event that the Disbursement Agent has not received any such written
directions, the Disbursement Agent shall be under no obligation to invest any
such money. Any income or gain realized as a result of any such investment shall
be held as part of the applicable Securities Account and reinvested as provided
in this Agreement until released in compliance with the terms of this Agreement.
Any income tax payable on account of any such income or gain shall be paid by
the Issuer. The Disbursement Agent shall have no liability for any loss
resulting from any such investment other than solely by reason of its willful
misconduct or gross negligence or bad faith or from failure to exercise such
care in the custody of any such investments as it does for accounts held by
other customers or in the custody of its own investments. Any such investment
may be sold (without regard to maturity date) by the Disbursement Agent as
directed in writing by the Issuer to make any distribution required by this
Agreement. In addition, if an Event of Default exists, the Disbursement Agent
shall liquidate and sell any investment if so directed in writing by the
Trustee, and shall invest any money held in any Securities Account only as
directed by the Trustee. The Issuer shall direct the Disbursement Agent to
invest any money held in the Interest Reserve Account only in such Permitted
Investments, as defined in, and in accordance with, the Indenture, that will
mature approximately on, but not later than, any of the first four Interest
Payment Dates, and with respect to each such Interest Payment Date, that will
mature in such amounts as will be sufficient to pay the interest that is due on
the First Mortgage Notes on such Interest Payment Date.

          2.9    REMEDIES. Notwithstanding any other provision of this
Agreement, in addition to the rights provided hereunder and at law or in equity
and to any rights and remedies provided in the Collateral Documents, upon an
Event of Default and for so long as such Event of Default exists, the
Disbursement Agent shall disburse funds from the Securities Accounts only as
directed by the Trustee, and the Trustee may exercise any or all of the
following remedies, successively or concurrently and in such order as the
Trustee elects:

                 (a)     The Trustee may deliver some or all of the notices
contemplated by SECTIONS 2.4, 2.5, 2.6, and 2.8.

                 (b)     Any cash that is Collateral held by the Disbursement
Agent and all cash proceeds received by the Disbursement Agent in respect of any
sale of, collection from, or other realization upon all or any part of the
Collateral shall be applied (after payment of any and all amounts payable to the
Disbursement Agent pursuant to the Collateral Documents) against the Obligations
for the benefit of the Trustee. Any surplus of such cash or cash proceeds held
by the Disbursement Agent and remaining after payment in full of all the
Obligations shall be paid

                                       20
<Page>

over to the Issuer or to whomsoever may be lawfully entitled to receive such
surplus or as a court of competent jurisdiction may direct.

                 (c)     The Issuer hereby irrevocably appoints the Trustee as
its attorney-in-fact effective upon and during the existence of an Event of
Default with full power of substitution to do any act which the Issuer is
obligated hereby to do, to exercise such rights as the Issuer might exercise
with respect to the Collateral and to execute and file in the Issuer's name any
financing statements and amendments thereto required or advisable to protect the
Trustee's rights or security interest hereunder and under any other Collateral
Documents. Such appointment and power of attorney shall be irrevocable and
coupled with an interest. The Trustee shall exercise all remedies under this
SECTION 2.9 in accordance with the terms of the Indenture.

          2.10   WAIVER OF SET-OFF RIGHTS. The Disbursement Agent hereby
acknowledges the Trustee's security interests as set forth above and under any
other Collateral Documents and waives any security interest or other lien in the
Collateral and further waives any right to set-off the Collateral now or in the
future against any indebtedness of the Issuer. The waivers set forth in this
SECTION 2.10 are of rights which may exist now or hereafter in favor of the
Disbursement Agent in its individual capacity, and not of any such rights which
may exist now or hereafter in favor of the Disbursement Agent in its capacity as
Disbursement Agent for the Trustee. Nothing in this SECTION 2.10 shall be
construed as waiving, limiting or diminishing any rights of the Trustee
vis-a-vis the Issuer.

          2.11   COOPERATION. The Disbursement Agent is hereby directed to
cooperate with the Trustee in the exercise of its rights in the Collateral
provided for herein. The Trustee may take all necessary action to preserve and
protect the security interests created hereby and by the other Collateral
Documents as a lien and encumbrance upon such Collateral and, upon demand, the
Issuer and the Disbursement Agent will execute and deliver to the Trustee such
instruments and documents as the Trustee may reasonably deem necessary or
advisable to confirm or perfect the rights of the Trustee under this Agreement
and the Trustee's interest in the Collateral.

          2.12   FUNDING MECHANICS FOR FF&E COSTS. The parties hereto
acknowledge that funds for the costs of acquisition and installation of the
Additional Funding FF&E will be made available to the Issuer through the FF&E
Financing or through the issuance of Additional Notes. Advances of funds under
the FF&E Financing, if any, will not be made pursuant to this Agreement but,
instead, will be made pursuant to separate agreements entered into between the
Issuer and the providers of FF&E Financing. In order to account for such FF&E
Financing for purposes of tracking the progress and status of the Facility
hereunder, including the amount of Available Construction Funds from time to
time, (i) the Issuer has represented that the Project Budget, Construction
Schedule and Plans include and reflect the work to be performed in connection
with the Additional Funding FF&E, (ii) the Disbursement Requests to be submitted
by the Issuer hereunder require the Issuer to, among other things, certify as to
the Project Costs incurred and work from time to time performed in connection
with the Additional Funding FF&E and the amounts drawn and amounts available to
be drawn under the FF&E Financing, and (iii) the Independent Construction
Consultant will confirm the Issuer's certifications and representations to the
extent set forth in the certificates to be submitted by the Independent
Construction Consultant hereunder from time to time unless the Independent
Construction

                                       21
<Page>

Consultant has a good faith basis, in its professional judgment, for withholding
its confirmation. Upon request by the Disbursement Agent or the Independent
Construction Consultant, the Issuer shall cause the providers of such FF&E
Financing to confirm the amounts drawn and the amounts available to be drawn
under such FF&E Financing (including interest or fees due and payable
thereunder). The Issuer shall cause the proceeds of any Additional Notes issued
before the Initial Operating Date to be deposited into the Construction
Disbursement Account and such proceeds will be advanced pursuant to this
Agreement.

          2.13   FUNDING MECHANICS FOR BOND FINANCING. The parties hereto
acknowledge that funds for the costs of acquisition, construction and
installation of certain land-based improvements and equipment will be disbursed
pursuant to both this Agreement and the Bond Financing Documents.

                 (a)     Construction Disbursement Requests submitted by the
Issuer may from time to time: (i) include as an attachment a copy of a completed
Bond Requisition (substantially in the form of Exhibit D to the Bond Loan
Agreement) signed by Premier and request that amounts be Disbursed from the
Construction Disbursement Account to the PFC Payment Account in an amount equal
to the total Permitted Land-Based Project Costs shown on the attached copy of
the completed Bond Requisition or (ii) request that amounts be Disbursed from
the Construction Disbursement Account to the PFC Payment Account to fund or
replenish the Company's Direct Payment Account in accordance with the terms
hereof.

                 (b)     All amounts transferred from the Construction
Disbursement Account to the PFC Payment Account upon satisfaction of the
conditions precedent to Disbursements set forth in this Agreement shall be
deemed to be an equity contribution by Premier to PFC.

                 (c)     In each such Construction Disbursement Request which
includes a request that amounts be Disbursed to the PFC Payment Account, PFC
will also:

                         (i)    confirm that the conditions precedent set forth
in SECTION 8 of the Bond Purchase Agreement have been satisfied or waived; and

                         (ii)   (1) in the case of clause (a)(i), instruct the
Disbursement Agent to immediately transfer such funds from the PFC Payment
Account to the Bond Trustee's Construction Disbursement Account to effect the
purchase of the Bonds and (2) in the case of clause (a)(ii), instruct the
Disbursement Agent to immediately transfer such funds from the PFC Payment
Account to the Company's Direct Disbursement Account to effect the purchase of
the Bonds. The Independent Construction Consultant shall review each such
Construction Disbursement Request (including those Project Costs separately
identified on the copy of the Bond Requisition submitted therewith) as part of
the conditions precedent to Disbursements in accordance with the requirements of
this Agreement. The Disbursement Agent's transfer of funds from the Construction
Disbursement Account to the PFC Payment Account and thereafter to the Bond
Trustee's Construction Disbursement Account or the Company's Direct Disbursement
Account, as instructed in such Construction Disbursement Request, shall make
funds available from time to time for PFC to purchase the Bonds and for loans to
be made to Premier to pay Permitted Land-Based Project Costs in accordance with
the Bond Financing Documents and SECTION 5.9 hereof.

                                       22
<Page>

    3.  CERTAIN RESPONSIBILITIES OF DISBURSEMENT AGENT AND INDEPENDENT
CONSTRUCTION CONSULTANT.

          3.1    DISBURSEMENTS FROM THE ACCOUNTS. Prior to making a
Disbursement, the Disbursement Agent shall telephone or email the Issuing Agent
for the Title Insurer on the requested disbursement date to confirm that the
Title Insurer is prepared to issue the Update Endorsement if an Update
Endorsement is required under SECTIONS 4.2.2(d), 4.6.1(a)(iii), 4.6.2(b) OR 4.7
(d), as applicable. The Disbursement Agent shall disburse funds from the
Securities Accounts, and the PFC Payment Account only upon satisfaction of the
applicable conditions to disbursement set forth herein. Upon satisfaction of the
applicable conditions to disbursement set forth herein, the Disbursement Agent
shall disburse funds from the applicable Securities Account and the PFC Payment
Account as specified in the applicable disbursement request or certificate.

          3.2    TRANSFER OF FUNDS AT DIRECTION OF TRUSTEE. Notwithstanding
anything to the contrary in this Agreement, from and after the date the
Disbursement Agent receives written notice from the Trustee or the Issuer that
an Event of Default (as defined in the Indenture) exists until such time as the
Disbursement Agent receives written notice from the Trustee that such Event of
Default no longer exists, the Disbursement Agent shall only withdraw or transfer
amounts in any Securities Account and the PFC Payment Account at the direction
of the Trustee.

          3.3    PAYMENT OF COMPENSATION.

                 3.3.1   COMPENSATION. On the first Business Day of each year
during the Construction Period (except for the initial payment, which shall be
disbursed as set forth in SECTION 4.1 below), the Disbursement Agent shall
disburse $6,000.00 from the Construction Disbursement Account to U.S. Bank
National Association, which amount shall constitute compensation for services to
be performed by it in its capacity as Disbursement Agent, Trustee and Bond
Trustee during such year. On the first Business Day of each year during the
Operating Period, the Issuer shall pay $6,000.00 to U.S. Bank National
Association, which amount shall constitute compensation for services to be
performed by Disbursement Agent, Trustee and Bond Trustee under the Transaction
Documents during such year.

                 3.3.2   INDEPENDENT CONSTRUCTION CONSULTANT'S COMPENSATION. The
Independent Construction Consultant shall deliver to the Disbursement Agent, on
or prior to the last Business Day of each month during the Construction Period,
an invoice setting forth the amounts owed to it as compensation for its services
during such month and reasonable documentation of its out-of-pocket expenses
incurred in connection with such services as provided in the Independent
Construction Consultant's Engagement Agreement. On the first Business Day of
each month during the Construction Period (except for the initial payment, which
shall be disbursed as set forth below), the Disbursement Agent shall disburse
funds to the Independent Construction Consultant from the Construction
Disbursement Account as compensation for services performed by the Independent
Construction Consultant during the previous month, as set forth on such invoice
(which amount shall not exceed a total of $20,000 during any calendar quarter),
plus the total amount of all out-of-pocket expenses of the Independent
Construction Consultant incurred in connection with the performance of its
duties hereunder during such month, unless the Trustee or Premier notifies the
Disbursement Agent and the Independent Construction Consultant that the
Independent Construction Consultant is in default. Until such time as the
Trustee provides written notice to the contrary to the

                                       23
<Page>

Disbursement Agent and the Independent Construction Consultant in accordance
with the terms hereof, all amounts payable to the Independent Construction
Consultant shall be applied to the "working capital and machine loads" line item
in the Project Budget.

                 3.3.3   PROCEDURE. The payments contemplated by this
SECTION 3.3 shall be made without the requirement of obtaining any further
consent or action on the part of the Issuer with respect to such payments.
Disbursements for each subsequent calendar month shall be made on the first day
of each such subsequent calendar month. The final payments pursuant to this
SECTION 3.3 shall also be prorated if for a partial month.

          3.4    PERIODIC REVIEW.

                 3.4.1   REVIEW BY DISBURSEMENT AGENT. The Disbursement Agent
shall exercise commercially reasonable efforts and utilize commercially prudent
practices in the performance of its duties hereunder consistent with those of
similar institutions holding similar collateral and disbursing similar
disbursement control funds. Commencing upon execution and delivery hereof, the
Disbursement Agent shall have the right, but shall have no obligation, to meet
periodically at reasonable times upon reasonable advance notice with
representatives of the Trustee, the Issuer, the Independent Construction
Consultant and such other employees, consultants or agents as the Disbursement
Agent shall reasonably request to be present for such meetings. In addition, the
Disbursement Agent shall have the right, but shall have no obligation, at
reasonable times during customary business hours and at reasonable intervals
upon prior notice to review, to the extent it deems reasonably necessary or
appropriate to permit it to perform its duties hereunder, all information
(including Construction Contracts) supporting any Disbursement Request and any
certificates in support of any of the foregoing. The Disbursement Agent shall be
entitled to examine, copy and make extracts of the books, records, accounting
data and other documents of the Issuer which are reasonably necessary or
appropriate to permit it to perform its duties hereunder, including, without
limitation, bills of sale, statements, receipts, contracts or agreements, which
relate to any materials, fixtures or articles incorporated into the Facility.
The rights of the Disbursement Agent under this SECTION 3.4 shall not be
construed as an obligation, it being understood that the Disbursement Agent's
duty is solely limited to act upon certificates and draw requests submitted by
the Issuer and the Trustee hereunder.

          3.5    REVIEW BY INDEPENDENT CONSTRUCTION CONSULTANT. The Independent
Construction Consultant shall exercise commercially reasonable efforts and
utilize commercially prudent practices in the performance of its duties
hereunder consistent with those of similar institutions disbursing disbursement
control funds and reviewing construction progress. Commencing upon execution and
delivery hereof, the Independent Construction Consultant shall have the right to
meet periodically at reasonable times during customary business hours and at
reasonable intervals, however no less frequently than monthly, with
representatives of the Issuer, the General Contractor, the Architect and such
other employees, consultants or agents as the Independent Construction
Consultant shall reasonably request to be present for such meetings. The
Independent Construction Consultant may perform such inspections of the Site and
the Facility as it deems reasonably necessary or appropriate in the performance
of its duties hereunder, however no less frequently than monthly. In addition,
the Independent Construction Consultant shall have the right at reasonable times
during customary business hours upon prior notice to review, to the extent it
deems reasonably necessary or appropriate to permit it to perform its duties
hereunder, all information (including Construction Contracts) supporting the

                                       24
<Page>

amendments to the Project Budget, amendments to any Construction Contracts, any
Construction Disbursement Request and any certificates in support of any of the
foregoing, to inspect materials stored on the Site and the Facility, at off-site
facilities where materials designated for use in the Facility are stored, to
review the insurance required pursuant to the terms of the Indenture, and to
examine the Plans and all shop drawings relating to the Facility. The
Independent Construction Consultant is authorized to contact any payee for
purposes of confirming receipt of progress payments. The Independent
Construction Consultant shall be entitled to examine, copy and make extracts of
the books, records, accounting data and other documents of the Issuer relating
to the construction of the Facility, including, without limitation, bills of
sale, statements, receipts, lien releases and affidavits, contracts or
agreements, which relate to any materials, fixtures or articles incorporated
into the Facility. From time to time, at the request of the Independent
Construction Consultant, the Issuer shall make available to the Independent
Construction Consultant a Project Cost Schedule and/or the Construction Schedule
for the Facility. The Issuer agrees to reasonably cooperate, shall cause the
General Contractor and each other Contractor to reasonably cooperate, with the
Independent Construction Consultant in assisting the Independent Construction
Consultant to perform its duties hereunder and to take such further steps as the
Independent Construction Consultant reasonably may request in order to
facilitate the Independent Construction Consultant's performance of its
obligations hereunder. The Independent Construction Consultant will confirm the
Issuer's certifications and representations to the extent set forth in the
certificates to be submitted by the Independent Construction Consultant
hereunder from time to time, and shall timely execute and deliver all
certificates provided for under this Agreement, in the form required by the
exhibits attached hereto, unless the Independent Construction Consultant has a
good faith basis, in its professional judgment, for withholding its
confirmation.

          3.6    THE SPECIAL PROCEDURES FOR UNPAID CONTRACTORS. The Issuer
agrees that the Disbursement Agent may make advances and transfer any or all
sums in the Construction Disbursement Account directly into the account of (a)
any Contractor for amounts due and owing to such Contractor under the relevant
Construction Contract or (b) any other subcontractors, vendors or materialsmen,
in each case in payment of amounts due and owing to such parties from the Issuer
without further authorization from the Issuer and the Issuer hereby constitutes
and appoints the Disbursement Agent its true and lawful attorney-in-fact to make
such direct payments and this power of attorney shall be deemed to be a power
coupled with an interest and shall be irrevocable; provided that, the
Disbursement Agent shall not exercise its rights under this power of attorney
except to make payments (a) as directed by the Issuer pursuant to a Disbursement
Request or (b) upon the occurrence and continuation of an Event of Default. No
further direction or authorization from the Issuer shall be necessary to warrant
or permit the Disbursement Agent to make such advances in accordance with the
foregoing sentence.

    4.  DISBURSEMENTS DURING CONSTRUCTION PERIOD.

          4.1    INITIAL DISBURSEMENTS FROM THE CONSTRUCTION DISBURSEMENT
ACCOUNT. Upon satisfaction of the conditions described below in this SECTION
4.1, the Disbursement Agent shall make the disbursements (the "INITIAL
DISBURSEMENTS") described in the Initial Disbursements Certificate attached
hereto as EXHIBIT A (the "INITIAL DISBURSEMENTS CERTIFICATE") from the
Construction Disbursement Account. The conditions to the Initial Disbursements
shall consist of the following:

                                       25
<Page>

                 (a)     (i) $33,100,000.00 of the Proceeds shall have been
deposited into the Interest Reserve Account, (ii) $1,031,900.00 of the Proceeds
shall have been deposited into the Tidelands Lease Account, and (iii) the
remaining Proceeds (in the amount of $128,962,500.00) shall have been deposited
into the Construction Disbursement Account;

                 (b)     (i) $34,819,190.29 of equity shall have been
irrevocably and unconditionally contributed to Premier on or prior to the
Issuance Date, and (ii) $15,180,809.71 of equity shall have been irrevocably and
unconditionally contributed to Premier and deposited contemporaneously with the
execution of this Agreement into the Construction Disbursement Account;

                 (c)     the Disbursement Agent shall have received the Issuer's
Closing Certificate and the Trustee's Closing Certificate; and

                 (d)     the Title Company shall have issued the Trustee's real
property title policy (or an irrevocable commitment to issue such title policy
conditioned only upon payment of [$381,636.45] for recording fees, title
premiums and real property taxes and the recordation of the Deeds of Trust and
the subordination nondisturbance and attornment agreements with Hard Rock Cafe
International (STP), Inc., a New York corporation, with respect to the Cafe
Lease and Retail Store Lease) in form and substance reasonably satisfactory to
the Trustee on the date specified in the Trustee's Closing Certificate.

          4.2    SUBSEQUENT DISBURSEMENTS FROM THE CONSTRUCTION DISBURSEMENT
ACCOUNT.

                 4.2.1   DISBURSEMENT REQUESTS.

                 (a)     The Issuer shall have the right from time to time
during the Construction Period to submit to the Disbursement Agent a request for
the disbursement of funds from the Construction Disbursement Account
substantially in the form of EXHIBIT C-1 hereto (a "CONSTRUCTION DISBURSEMENT
REQUEST") or in the form of EXHIBIT C-2 hereto (a "PRE-OPENING DISBURSEMENT
REQUEST" and, together with a Construction Disbursement Request, each a
"DISBURSEMENT REQUEST"), together with the exhibits attached thereto, as further
described below. The Disbursement Agent shall comply with any Disbursement
Request that satisfies each of the conditions set forth in SECTION 4.2.2. The
Disbursement Agent shall notify the Issuer and the Trustee in writing as soon as
reasonably possible (and in any event: (i) within two (2) Business Days after
the Disbursement Agent receives a Disbursement Request relating solely to the
Barge Construction Contract; or (ii) within five (5) Business Days after the
Disbursement Agent receives any other Disbursement Request) if any Disbursement
Request fails to satisfy any such condition which notice shall describe the
nature of such failure in reasonable detail. The Issuer may submit Construction
Disbursement Requests no more often than weekly. The Issuer may submit
Pre-Opening Disbursement Requests no more often than weekly. The Issuer shall
have the right from time to time during the Construction Period to submit to the
Disbursement Agent a preliminary Disbursement Request requesting that a
Disbursement be made meeting the requirements set forth in this SECTION 4.2. The
Disbursement Agent and the Independent Construction Consultant shall promptly
review the preliminary Disbursement Request and advise the Issuer of any
discrepancies, disputes or missing or incomplete information with respect
thereto necessary to make the preliminary Disbursement Request a conforming
Disbursement Request. The Issuer shall not be entitled to any Disbursement
unless and until a final, executed

                                       26
<Page>

Disbursement Request, with all exhibits and attachments thereto, has been
properly completed and submitted to the Disbursement Agent and the Independent
Construction Consultant in accordance with this SECTION 4.2. Each preliminary
Disbursement Request shall be clearly labeled as such with the phrase
"PRELIMINARY DISBURSEMENT REQUEST" at the top of the first page, and in lieu of
Premier's signature.

                 (b)     Provided that a Disbursement Request satisfies the
requirements of SECTION 4.2.2, within: (i) two (2) Business Days following
submission of a Disbursement Request relating solely to the Barge Construction
Contract; or (ii) five (5) Business Days following submission of any other
Disbursement Request:

                         (i)    the Disbursement Agent shall distribute checks
drawn on (or wire transfers from) the Construction Disbursement Account to the
parties identified in such Disbursement Request to pay Other Project Costs in
the respective amounts listed for such parties in such Disbursement Request;

                         (ii)   the Disbursement Agent shall transfer from the
Construction Disbursement Account to the Issuer's Payment Account funds in the
amount specified in such Disbursement Request;

                         (iii)  solely with respect to Construction Disbursement
Requests, the Disbursement Agent shall transfer from the Construction
Disbursement Account to the PFC Payment Account funds in the amount specified in
such Disbursement Request (which shall be deemed to be an equity contribution to
PFC); and

                         (iv)   immediately after such funds have been
transferred into the PFC Payment Account as described in clause (iii) above, the
Disbursement Agent shall disburse such funds from the PFC Payment Account to the
Bond Trustee's Construction Disbursement Account and the Company's Direct
Disbursement Account in the amounts specified in such Disbursement Request.

The Issuer shall withdraw funds from and write checks on the Issuer's Payment
Account solely for the purpose of paying Construction Expenses and Pre-Opening
Expenses, as the case may be, identified on such Disbursement Request; PROVIDED,
HOWEVER, that any Contractors or other parties in direct contractual privity
with Premier and scheduled to be paid Project Costs in excess of $100,000 shall
be listed in any particular Disbursement Request as a party to be paid directly
by the Disbursement Agent under clause (i) above (or, in the case of Permitted
Land-Based Project Costs, by the Bond Trustee under the Bond Financing
Documents) and may not be paid from the Issuer's Payment Account. The Issuer
shall use the amounts disbursed from the PFC Payment Account to the Bond
Trustee's Construction Disbursement Account solely for the purposes of
purchasing Bonds and paying Permitted Land-Based Project Costs as identified on
the copy of the Bond Requisition attached to such Disbursement Request. The
Issuer shall use the amounts disbursed from the PFC Payment Account to the
Company's Direct Disbursement Account solely for the purposes of purchasing
Bonds and paying, from time to time, Permitted Land-Based Project Costs.

                 (c)     The Trustee may waive any condition to a disbursement
requested in a Disbursement Request.

                                       27
<Page>

                 4.2.2   ADDITIONAL CONDITIONS TO SUBSEQUENT DISBURSEMENTS FROM
THE CONSTRUCTION DISBURSEMENT ACCOUNT. The Disbursement Agent's compliance with
a Disbursement Request from the Construction Disbursement Account, other than
the Initial Disbursements, shall be subject to the following conditions in
addition to the conditions set forth in SECTION 4.2.1 above. Upon satisfaction
of the conditions described below, the Disbursement Agent shall make the
disbursements specified in the corresponding Disbursement Request in accordance
with SECTION 4.2.1(b):

                 (a)     With respect to the Construction Disbursement Request,
the Issuer shall have submitted to the Disbursement Agent a Construction
Disbursement Request as provided for herein pertaining to the amounts requested
for disbursement, together with (i) completed SCHEDULES 1 AND 3 thereto
substantially in the form contemplated thereby, (ii) a completed SCHEDULE 2
thereto substantially in the form contemplated, (iii) all lien releases,
affidavits and agreements required to be attached under clause (c) of such
Construction Disbursement Request; (iv) the commitment from the Title Insurer to
issue an Update Endorsement if an Update Endorsement is required to be attached
pursuant to SECTION 4.2.2(d); and (v) the certifications of the General
Contractor, the Independent Construction Consultant and the Architect
substantially in the form of EXHIBITS 1, 2, and 3 to the Construction
Disbursement Request; to the extent required pursuant to the terms of the
Construction Disbursement Request;

                 (b)     With respect to any Pre-Opening Disbursement Request,
the Issuer shall have submitted to the Disbursement Agent a Pre-Opening
Disbursement Request as provided for herein pertaining to the amounts requested
for disbursement, together with a completed SCHEDULE 1 thereto substantially in
the form contemplated thereby;

                 (c)     The Trustee and the Independent Construction Consultant
shall have received copies of all Construction Contracts executed as of the date
of any Construction Disbursement Request and, with respect to each Material
Construction Contract executed on or before the date of such Construction
Disbursement Request: (i) a consent signed by the counterparty to such Material
Construction Contract if and to the extent required under SECTION 5.3; and (ii)
copies of any performance and payment bonds required pursuant to such Material
Construction Contract. Such bonds shall name the Issuer and the Trustee as
co-obligees and shall be in full force and effect;

                 (d)     Until such time as the aggregate amount of all prior
Disbursements equals or exceeds the aggregate principal amount of the First
Mortgage Notes then outstanding, the Issuer shall have caused the Title Insurer
to have delivered to the Independent Construction Consultant a commitment from
the Title Insurer in the form of EXHIBIT N-1 to issue an endorsement to the
Trustee's Title Policies increasing the coverage under the disbursement clause
of the Trustee's Title Insurance Policies by the amount of the requested
Disbursement (without adding any additional exclusions or exceptions to
coverage) (an "UPDATE ENDORSEMENT"), conditioned solely upon the making of the
Disbursement within five (5) Business Days after the issuance of such
commitment. The Issuer shall cause the Title Insurer to deliver each required
Update Endorsement to the Trustee (with a copy to the Independent Construction
Consultant) within five (5) Business Days after the making of such Disbursement;

                 (e)     The Issuer shall have delivered to the Independent
Construction Consultant a written inventory substantially in the form of
SCHEDULE 3 to the Issuer's

                                       28
<Page>

Disbursement Request identifying all materials, machinery, fixtures, furniture,
equipment or other items purchased or manufactured for incorporation into the
Facility but which, at the time of the Disbursement Request, (x) are not located
at the Site and for which the Issuer has paid or intends to pay with the
proceeds of the Disbursement all or a portion of the purchase price, or (y) are
located at the Site but are not expected to be incorporated into the Facility
within ninety (90) days after such Disbursement Request (such materials, the
"UNINCORPORATED MATERIALS") and including the value thereof, together with
evidence reasonably satisfactory to the Independent Construction Consultant that
the following conditions have been satisfied with respect to such Unincorporated
Materials:

                         (i)    all Unincorporated Materials for which full
payment has previously been made or is being made with the proceeds of the
Disbursement to be disbursed are, or will be upon full payment, owned by the
Issuer, as evidenced by the bills of sale, certificates of title or other
evidence reasonably satisfactory to the Independent Construction Consultant, and
all lien rights or claims of the supplier has been or will be released
simultaneously with such full payment and all amounts, if any, required to be
paid to the supplier thereof with respect to the installation of such
Unincorporated Materials (including any Retainage Amounts) (PROVIDED, HOWEVER,
that lien releases, affidavits and agreements need not be provided for
Unincorporated Materials from a single supplier with a contract price (or
expected aggregate amount to be paid in the case of "cost plus" contracts) of
less than $100,000);

                         (ii)   the Issuer believes that the Unincorporated
Materials are consistent with the Final Plans;

                         (iii)  all Unincorporated Materials are properly
inventoried, securely stored, protected against theft and damage at the Site or
at such other location which has been specifically identified by its complete
address to the Independent Construction Consultant (or if the Issuer cannot
provide the complete address of the current storage location, the Issuer shall
list the name and complete address of the applicable contracting party supplying
or manufacturing such Unincorporated Materials);

                         (iv)   are insured against casualty, loss and theft for
an amount equal to their replacement costs in accordance with the Indenture;

                         (v)    the amounts paid by the Issuer in respect of
Unincorporated Materials not at the Site (other than those related to the Barge
Construction Contract) are not more than $2,000,000 at any one time;

                         (vi)   the amounts paid by the Issuer in respect of
Unincorporated Materials not at the Site and related to the Barge Construction
Contract are not more than $9,000,000 at any one time;

                         (vii)  the Independent Construction Consultant shall
have confirmed the accuracy of the certification required in subparagraph (iii)
above, and in connection therewith the Independent Construction Consultant may,
but shall not be required to, visit the site of and inspect the Unincorporated
Materials at the Issuer's expense; and

                                       29
<Page>

                         (viii) The Independent Construction Consultant, at the
request of the Issuer, may from time to time agree to increase the thresholds
set forth in clauses (v) and (vi) above;

                 (f)     The following condition only applies to the first
Disbursement made after January 31, 2005: The Issuer shall have caused the Title
Insurer to have delivered to the Trustee (with a copy to the Independent
Construction Consultant) an updated separate tax lot endorsement to the
Trustee's Title Policies. The updated separate tax lot shall: (i) be in the form
of EXHIBIT N-2; (ii) insure that Parcels 2, 3, 4, 5, and 6 consist of separate
tax parcels; and (iii) shall be delivered prior to January 31, 2005;

                 (g)     The Disbursement Request on its face has been completed
as to the information required therein and the required attachments, if any, are
attached;

                 (h)     The Disbursement Agent shall not have Knowledge of any
material error, inaccuracy, misstatement or omission of material fact in any
Disbursement Request or an exhibit or attachment thereto or information provided
by the Issuer upon the request of the Disbursement Agent;

                 (i)     The Disbursement Agent does not have Knowledge (solely
from the facts set forth in any Disbursement Request or any certificate from the
General Contractor, the Independent Construction Consultant or the Architect or
any written notice from the Trustee or the Issuer) that an Event of Default
exists;

                 (j)     The Disbursement Agent shall have telephoned or emailed
the Issuing Agent for the Title Insurer on the requested disbursement date and
prior to making the requested Disbursement and confirmed that the Title Insurer
is prepared to issue the Update Endorsement if an Update Endorsement is required
under clause (d) above;

                 (k)     The Disbursement Agent shall be entitled to rely upon
the certification of the Issuer, the General Contractor, the Architect and the
Independent Construction Consultant in the relevant Disbursement Request in
determining that the conditions specified in SECTIONS 4.2.2(a) THROUGH 4.2.2(f)
have been satisfied unless the Disbursement Agent shall have Knowledge that such
certifications are inaccurate; and

                 (l)     Concurrently with the submission of the Construction
Disbursement Request, the Issuer shall submit an Available Construction Funds
Certificate to the Disbursement Agent, the Trustee and the Independent
Construction Consultant in accordance with SECTION 5.4 and, if applicable, a
Tidelands Lease Certificate to the Disbursement Agent in accordance with SECTION
6.1.

                 4.2.3   NON-SATISFACTION OF CONDITIONS. In the event that the
Disbursement Agent determines that any conditions of SECTION 4.2.2 described
above has not been satisfied in respect of any Construction Disbursement Request
and so long as such conditions are not satisfied, the Disbursement Agent shall
not authorize any disbursement of funds from the Construction Disbursement
Account pursuant to a Construction Disbursement Request; PROVIDED, HOWEVER, the
following payments may be made by the Disbursement Agent:

                                       30
<Page>

                 (a)     if all other conditions in SECTION 4.1 and
SECTION 4.2.2 hereof are met (except for SECTION 4.2.2(i), payments for work
completed or materials purchased on or prior to the date that the Disbursement
Agent determined that condition (i) of SECTION 4.2.2 was not satisfied and has
so notified the Issuer in writing;

                 (b)     payments not to exceed $5,000,000 in the aggregate to
prevent the condition of the Facility from deteriorating or to preserve any work
completed as certified to be reasonably necessary or advisable by the Issuer (in
writing); and

                 (c)     if such condition continues for a period of three
consecutive months or more, at the request of the Issuer, Retainage Amounts for
the portion of the Facility completed; provided that the Issuer certifies that
the conditions for paying such amounts (other than completion of the Facility)
are met.

          4.3    ADVANCE CONSTRUCTION DISBURSEMENTS.

                 (a)     In addition to the payments permitted by SECTION 4.2.3,
the Issuer shall have the right from time to time (but no more frequently than
once per calendar month, unless otherwise permitted by the Disbursement Agent)
to deliver to the Disbursement Agent an Advance Construction Disbursement
Request in the form of EXHIBIT C-3 (an "ADVANCE CONSTRUCTION DISBURSEMENT
REQUEST"), which Advance Construction Disbursement Request shall not be required
to include or attach the supporting documentation required for all other
Construction Disbursement Requests; PROVIDED, HOWEVER, that in the event a
Default or Event of Default subsequently exists (in addition to any other rights
and remedies hereunder or permitted by law), the Issuer shall promptly take all
action reasonably required to cause to be delivered to the Independent
Construction Consultant all supporting documentation with respect thereto that
would otherwise be required for a Construction Disbursement Request.

                 (b)     In any Advance Construction Disbursement Request, the
Issuer may request payment to any Contractor of Disputed Amounts so long as the
Available Advance Construction Disbursement Amount minus the aggregate amount
requested to be disbursed in such Advance Construction Disbursement submitted
under this SECTION 4.3 is greater than zero.

                 (c)     In addition, in any Advance Construction Disbursement
Request, the Issuer may request a disbursement to the PFC Payment Account to
enable PFC to purchase Bonds the proceeds from which will not be immediately
disbursed by the Bond Trustee to pay Permitted Land-Based Project Costs. In such
event, PFC may instruct the Disbursement Agent to transfer such funds from the
PFC Payment Account to the Company's Direct Disbursement Account to write checks
against from time to time (rather than being disbursed by the Bond Trustee
directly to Contractors for payment of Project Costs as set forth in a Bond
Requisition). The aggregate amount then outstanding with respect to all Advance
Construction Disbursements submitted under this clause (c) which have not been
documented as required in this Agreement for other Disbursements shall not
exceed $500,000.

                 (d)     The Disbursement Agent shall comply with any Advance
Construction Disbursement Request, so long as (i) the Advance Construction
Disbursement Request on its face has been completed as to substantially all the
information required therein; (ii) the Disbursement Agent shall not have
received written notice by any party hereto that a

                                       31
<Page>

Default or an Event of Default exists; and (iii) the Issuer and the Independent
Construction Consultant certify that the Available Advance Construction
Disbursement Amount MINUS the amount of the then requested Advance Construction
Disbursement shall be greater than zero.

          4.4    INTEREST RESERVE ACCOUNT DISBURSEMENTS.

                 (a)     At least five (5) Business Days prior to each Interest
Payment Date during the Construction Period, the Issuer shall deliver to the
Disbursement Agent a certificate in the form of EXHIBIT C-4 certifying as to the
amount required to be paid with respect to the First Mortgage Notes under the
Indenture on such Interest Payment Date and the calculation of such amount. On
each such Interest Payment Date, Disbursement Agent shall liquidate securities
held in the Interest Reserve Account (to the extent required) and pay over to
the Trustee the amounts due with respect to the First Mortgage Notes, as
specified in such certificate, from the Interest Reserve Account. In the event
that the Issuer fails to deliver the certificate required by the first sentence
of this paragraph (or sets forth in such certificate an incorrect calculation of
the amount required to be paid with respect to the First Mortgage Notes under
the Indenture on such Interest Payment Date), the Trustee may direct the
Disbursement Agent to liquidate such securities (to the extent required), and
disburse to the Trustee the amounts necessary to pay the amounts due with
respect to the First Mortgage Notes. In the event there are insufficient funds
in the Interest Reserve Account to pay any amount due pursuant to such
certificate or direction so given by the Trustee, the Issuer shall, prior to the
applicable Interest Payment Date, deposit in cash into the Interest Reserve
Account an amount equal to such deficiency; PROVIDED, HOWEVER, that the Trustee
shall direct the Disbursement Agent to disburse an amount equal to such
deficiency from the Construction Disbursement Account to the Interest Reserve
Account in the event such amounts are not received from the Issuer on a timely
basis. The Issuer acknowledges that any failure by the Issuer to provide notice
or deposit funds referenced in this SECTION 4.4(a) shall not in any way
exonerate or diminish its obligation to make all payments under the Indenture as
and when due.

                 (b)     The parties generally intend that the portion of the
Proceeds that will be held in the Interest Reserve Account will equal the
difference (the "INITIAL INTEREST RESERVE ACCOUNT TARGET") of (a) the aggregate
amount of the interest payments that will be due on the First Mortgage Notes on
each of the first four Interest Payment Dates (the "INTEREST RESERVE INCOME
REQUIREMENT") less (b) the amount of interest and other income that the Issuer
reasonably expects to earn on amounts held in the Interest Reserve Account (the
"EXPECTED INTEREST RESERVE INCOME AMOUNT"). The portion of the Proceeds that
will be deposited into the Interest Reserve Account contemporaneously with the
execution of this Agreement may exceed the Initial Interest Reserve Account
Target since the Expected Interest Reserve Income Amount will be established
with greater clarity after the Issuer directs the Disbursement Agent in writing
to invest such Proceeds. As such, within five (5) Business Days after the date
hereof, the Issuer shall deliver to the Disbursement Agent a request for the
disbursement of such excess funds from the Interest Reserve Account to the
Construction Disbursement Account in the form of EXHIBIT C-5 hereto. The
Disbursement Agent shall, after receiving such request, transfer such amounts
specified on such request to the Construction Disbursement Account. On the
second (2nd) Business Day after the Disbursement Agent's receipt of written
confirmation from the Trustee that each of the four interest payments with
respect to the First Mortgage Notes required to be made to the Trustee under
this Section have been received by the Trustee and provided that the
Disbursement Agent has not received written notice from the Trustee or the
Issuer that

                                       32
<Page>

an Event of Default exists, the Disbursement Agent shall release all remaining
funds in the Interest Reserve Account to (A) the Construction Disbursement
Account if the release of funds therefrom permitted under SECTION 4.6 shall have
not yet occurred; and (B) an account designated by the Issuer, if the release of
funds permitted under SECTION 4.6 has occurred.

          4.5    ISSUER'S REIMBURSEMENT OF PREVIOUSLY FUNDED PROJECT COSTS. If,
at any time and from time to time, the Issuer shall be unable to satisfy the
conditions precedent to any disbursement set forth in this Article, the Issuer
shall be entitled to pay Project Costs then due and owing and to later seek
reimbursement of such Project Costs from the Construction Disbursement Account
as part of a Disbursement Request as and when permitted in accordance with the
terms of this Agreement at the time (if any) that the Issuer is able to satisfy
the conditions precedent to disbursement set forth in this Article.

          4.6    DISBURSEMENT OF FUNDS IN CONSTRUCTION PERIOD ACCOUNTS FOLLOWING
THE INITIAL OPERATING DATE.

                 4.6.1   IF THE CONDITIONS SET FORTH IN CLAUSES (a), (b) AND (c)
BELOW ARE SATISFIED:

                 (a)     The Issuer provides to the Disbursement Agent (with a
copy to the Independent Construction Consultant and the General Contractor):

                         (i)    an Officer's Certificate in the form of EXHIBIT
G-1 attached hereto certifying that:

                                (A)  the Facility is Operating and has been
Operating uninterrupted for at least ten (10) days prior to the date of the
certification;

                                (B)  all amounts required to be paid to
Contractors in connection with causing the Facility to become Operating have
been paid, other than Permitted Amounts, so long as: (1) 175% of the Punchlist
Completion Amount for such uncompleted Punchlist Items shall have been reserved
in the Construction Disbursement Account; (2) 125% of the Disputed Amounts with
respect to the GMP Contract shall have been reserved in the Construction
Disbursement Account; (3) 200% of the Disputed Amounts for any Construction
Contract other than the GMP Contract shall have been reserved in the
Construction Disbursement Account; and (4) 100% of the Retainage Amounts shall
have been reserved in the Construction Disbursement Account (this clause (4),
collectively with amounts under clauses (1), (2) and (3) the "RESERVED AMOUNT");

                                (C)  the Issuer has received lien releases,
affidavits and agreements from Premier and each Contractor in the form of
EXHIBIT M-1, M-2 OR M-3, as applicable (other than (1) with respect to Permitted
Amounts described in clause (B) above and (2) from a single Contractor with a
contract price (or expected aggregate amount to be paid in the case of "cost
plus" contracts) of less than $100,000); and

                                (D)  there are no mechanic's liens or other
liens, charges or orders filed against the Facility or any portion thereof by
any Contractor or any other party that have not been discharged of record or
bonded, other than Permitted Liens;

                                       33
<Page>

                         (ii)   a certificate of the Independent Construction
Consultant confirming the factual certification described in clause (i) above;
and

                         (iii)  unless at such time the aggregate amount of all
prior Disbursements equals or exceeds the aggregate principal amount of the
First Mortgage Notes then outstanding, a commitment from the Title Insurer in
the form of EXHIBIT N-1 to issue an Update Endorsement to the Trustee's Title
Policies increasing the coverage under the disbursement clause of the Trustee's
Title Insurance Policies by the amount of the requested Disbursement,
conditioned solely upon the making of the requested Disbursement within five (5)
Business Days after the issuance of such commitment. The Issuer shall cause the
Title Insurer to deliver the Update Endorsement to the Trustee (with a copy to
the Independent Construction Consultant) within five (5) Business Days after the
making of such Disbursement;

                 (b)     The General Contractor has not delivered an objection
certificate in the form of EXHIBIT G-2 to the Disbursement Agent, Premier and
the Independent Construction Consultant objecting to Premier's calculation of
the Permitted Amounts set forth in the Officer's Certificate delivered pursuant
to clause (a)(i) above within five (5) Business Days after Premier's delivery
thereof to the Disbursement Agent; and

                 (c)     The Disbursement Agent shall have telephoned or emailed
the Issuing Agent for the Title Insurer on the requested disbursement date, and
prior to making the requested Disbursement, and confirmed that the Title Insurer
is prepared to issue any Update Endorsement required under clause (a)(iii)
above;

THEN the Disbursement Agent shall, within five (5) Business Days after the
direction of the Issuer pursuant to the Officer's Certificate delivered pursuant
to clause (a)(i) above, disburse all funds on deposit in the Construction
Disbursement Account, if any, excluding the Reserved Amount set forth in such
Officer's Certificate, to the Issuer's account specified in such Officer's
Certificate.

                 4.6.2   If the General Contractor delivers an objection
certificate in the form of Exhibit G-2 to the Disbursement Agent, the
Independent Construction Consultant and Premier within five (5) Business Days
after the date Premier delivers its Officer's Certificate to the Disbursement
Agent under SECTION 4.6.1(a)(i) above, THEN:

                 (a)     the Officer's Certificate, Independent Construction
Consultant's certificate and commitment to issue the Update Endorsement
previously delivered to the Disbursement Agent shall be invalid;

                 (b)     Premier shall revise its Officer's Certificate to
calculate the Reserved Amount based on the Permitted Amounts set forth in the
objection certificate delivered by the General Contractor (so long as the
Permitted Amounts set forth in such objection certificate do not exceed the
various thresholds for Permitted Amounts set forth in the definition of
"Permitted Amounts" in SECTION 1 hereof) and re-deliver the same, together with
the items required under CLAUSES (ii) AND (iii) OF SECTION 4.6.1(a) to the
Disbursement Agent;

                 (c)     the Disbursement Agent shall have telephoned or emailed
the Issuing Agent for the Title Insurer on the requested disbursement date and
prior to making the

                                       34
<Page>

requested Disbursement and confirmed that the Title Insurer is prepared to issue
any Update Endorsement delivered as required under clause (b) above.

If (i) the Permitted Amounts set forth in such objection certificate or such
revised Officer's Certificate exceed the various thresholds for Permitted
Amounts set forth in the definition of "Permitted Amounts" in SECTION 1 hereof
or (ii) Premier fails to re-deliver the items required under SECTION 4.6.2(b)
above to the Disbursement Agent or (iii) the Disbursement Agent is unable to
confirm verbally or by email that the Title Insurer is prepared to issue any
Update Endorsement delivered as required SECTION 4.6.2(c) above, THEN no
Disbursement shall be made from the Construction Disbursement Account until such
time as the conditions set forth in this SECTION 4.6 shall have been satisfied.

If the conditions set forth in SECTIONS 4.6.2(b)AND (c) above have been
satisfied, then the Disbursement Agent shall, upon the direction of the Issuer
pursuant to the revised Officer's Certificate delivered pursuant to SECTION
4.6.2(b), disburse all funds on deposit in the Construction Period Accounts, if
any, excluding the Reserved Amount set forth in such revised Officer's
Certificate, to the Issuer's account specified in such Officer's Certificate.

          4.7    FINAL DISBURSEMENT OF FUNDS IN CONSTRUCTION PERIOD ACCOUNTS.
If the Issuer provides:

                 (a)     to the Disbursement Agent an Officer's Certificate in
    the form of EXHIBIT G-3 attached hereto to the effect that (i) the Facility
    is Operating and has been Operating uninterrupted for at least ten (10) days
    prior to the date of the certification, (ii) all amounts required to be paid
    to Contractors have been paid, (iii) the Issuer has received final lien
    releases, affidavits and agreements from Premier and from each Contractor in
    the form of EXHIBIT M-4, M-5 OR M-6, as applicable (PROVIDED, HOWEVER, lien
    releases, affidavits and agreements need not be provided for from a single
    Contractor with a contract price (or expected aggregate amount to be paid in
    the case of "cost plus" contracts) of less than $100,000); and (iv) there
    are no mechanic's liens or other liens, charges or orders filed against the
    Facility or any portion thereof by any Contractor or any other party that
    have not been discharged of record or bonded to other than Permitted Liens;

                 (b)     a certificate of each of the General Contractor and the
    Independent Construction Consultant confirming the factual certification
    described in clause (a) above;

                 (c)     unless at such time the aggregate amount of all prior
    Disbursements equals or exceeds the aggregate principal amount of the First
    Mortgage Notes then outstanding, a commitment from the Title Insurer in the
    form of EXHIBIT N-1 to issue an Update Endorsement to the Trustee's Title
    Policies increasing the coverage under the disbursement clause of the
    Trustee's Title Insurance Policies by the amount of the requested
    Disbursement, conditioned solely upon the making of the requested
    Disbursement within five (5) Business Days after the issuance of such
    commitment. The Issuer shall cause the Title Insurer to deliver the Update
    Endorsement to the Trustee (with a copy to the Independent Construction
    Consultant) within five (5) Business Days after the making of such
    Disbursement; and

                                       35
<Page>

                 (d)     The Disbursement Agent shall have telephoned or emailed
    the Issuing Agent for the Title Insurer on the requested disbursement date
    and prior to making the requested Disbursement and confirmed that the Title
    Insurer is prepared to issue any Update Endorsement required under clause
    (d) above;

THEN the Disbursement Agent shall, upon the direction of the Issuer pursuant to
the Officer's Certificate delivered pursuant to clause (a) above, disburse all
remaining funds in the Construction Disbursement Account, if any, to the
Issuer's account specified in such Officer's Certificate.

          4.8    TIDELANDS LEASE DISBURSEMENTS. The Disbursement Agent shall
liquidate securities held in the Tidelands Lease Account (to the extent
required) and disburse such funds from the Tidelands Lease Account:

                 (a)     if Premier provides to the Disbursement Agent an
Officer's Certificate in the form of EXHIBIT G-4 attached hereto: (i) specifying
the name of the payee; (ii) the payment information of the payee; and (iii)
certifying that the Tidelands Lease requires Premier to pay such amount to the
payee; or

                 (b)     as directed by the State of Mississippi upon the
receipt of a written notice from the State of Mississippi that Premier is in
default under the Tidelands Lease, and that such default has not been cured by
Premier, and that such default may be cured by the payment of a liquidated sum
of money to the State of Mississippi.

    5.  CERTAIN CONSTRUCTION PERIOD COVENANTS.

          The following covenants apply only during the Construction Period:

          5.1    AMENDMENTS TO PROJECT BUDGET. The Project Budget for the
Facility may be amended from time to time in the manner set forth herein. The
Issuer shall have the right from time to time to amend the Project Budget
without consent of the Trustee, Independent Construction Consultant or any other
party to this Agreement to change the amounts allocated for specific line item
components of the Facility; PROVIDED that, in any such amendment, the Issuer may
neither modify the description of any line item nor modify the Pre-Issuance
Expense amount set forth for any such line item and, for each line item, the
Remaining Budgeted Amount must equal the difference of the Total Budgeted Amount
for such line item less the amount of Pre-Issuance Expenses for such line item.

                 5.1.1   SOURCES OF FUNDS FOR LINE-ITEM INCREASES. A line item
in the Project Budget may be increased only if the funds for such increase are
made available in the Project Budget from:

                 (a)     an increase in Additional Pre-Operating Revenue to
the extent not previously expended or dedicated to the payment of items
contained in the Project Budget;

                 (b)     an increase in Realized Savings from another line item
and a corresponding reduction in the construction line items related to such
Realized Savings; or

                                       36
<Page>

                 (c)     the reduction of the "contingency" line item in the
Project Budget, PROVIDED, HOWEVER, that the "contingency" line item may not be
reduced below Five Million Dollars ($5,000,000) until the date that is
forty-five (45) days after the date the Final Plans have been completed and such
reserved amount shall not be available for application to any other line item in
the Project Budget unless and until the Final Plans have been completed.

                 5.1.2   PROJECT BUDGET AMENDMENT PROCESS. Any amendment to the
Project Budget shall be in writing. Any such amendment shall identify with
particularity the line item to be increased or decreased, if any, the amount of
the increase or decrease (if any), and in the event of an increase in a
construction line item, the Realized Savings, Additional Pre-Operating Revenue,
and/or line item for "contingency" in the Project Budget permitted to be reduced
pursuant to SECTION 5.1.1 (but not any Retainage Amounts), which are proposed to
be utilized to pay for the increase; and (y) in the case of a decrease in a
construction line item, the Realized Savings in the amount of such decrease. The
parties acknowledge that a portion of any cost reduction achieved with respect
to the work performed under a Construction Contract may be payable to the
General Contractor or another Contractor under such Construction Contract
(subject to the conditions contained in the GMP Contract or such other
Construction Contract with respect to application of savings) and that in such
case the entire reduction may not become Realized Savings. Construction line
items may be reduced only upon obtaining, and in the amount of, Realized
Savings. The total amount allocated in the Project Budget for the line items for
Finishes, as such line items are set forth on EXHIBIT D-3 hereto, may not be
reduced by more than fifteen percent (15%) of the sum of the amounts allocated
to such line items on EXHIBIT D-3 hereto. The "pre-opening expenses" line item
on the Project Budget may not be reduced by more than fifteen percent (15%). The
"contingency" line item on the Project Budget may be reduced by allocation to
other line items subject to the restrictions contained in SECTION 5.1.1(c). The
"working capital and machine loads" line item, the "excess liquidity" line item,
the "owner supplied FF&E" line item, and the "FF&E" line item on the Project
Budget may not be reduced. Any amounts of Realized Savings, Additional
Pre-Operating Revenue, contingency amounts or previously allocated reserves so
identified for use in connection with a particular line item thenceforth shall
be deemed dedicated to the particular line item, unless and until the Project
Budget is amended to reduce the amounts budgeted for the line item of the
Project Budget. Notwithstanding the foregoing, at any time Soft Costs may be
applied against the "excess liquidity" line item of the Project Budget;
PROVIDED, HOWEVER that (x) $ 3,000,000.00 constitutes a reserve against which no
Project Costs may be applied and represents amounts that can only be disbursed
to the Issuer upon satisfaction of the conditions precedent in Section 4.6, and
(y) $1,031,900.00 shall be deposited concurrently with the execution of this
Agreement into the Tidelands Lease Reserve Account and constitutes a reserve
that can only be disbursed upon satisfaction of the conditions precedent in
Section 4.8.

                 5.1.3   PROJECT BUDGET AMENDMENT CERTIFICATE. The Issuer shall
submit the Project Budget amendment to the Disbursement Agent by an Officer's
Certificate in the form of EXHIBIT E hereto (an "PROJECT BUDGET AMENDMENT
CERTIFICATE") together with the certificates of the General Contractor (for Hard
Costs under GMP Contract (including "Direct Purchase Items" as defined in GMP
Contract) if modified by such Project Budget amendment), Independent
Construction Consultant and Architect (for Hard Costs with respect only to Plans
prepared by it) as provided in the form of EXHIBITS 1 through 3 to the Project
Budget Amendment Certificate. Upon submission of such Project Budget Amendment
Certificate, together with the

                                       37
<Page>

Exhibits thereto, such amendment shall become effective hereunder, and the
Project Budget for the Facility shall thereafter be as so amended.

          5.2    CONSTRUCTION CONTRACT AMENDMENT PROCESS. The Issuer shall not
enter into or approve any Construction Contract Amendment except as set forth in
this SECTION 5.2. The Issuer shall have the right from time to time to amend any
Construction Contract to change the scope of work for any portion of the
Facility and/or the Issuer's payment obligations in connection therewith. Any
Construction Contract Amendment that (i) results in a cost increase in a
Material Construction Contract in excess of $250,000, individually (or, with
respect to the GMP Contract only, in excess of $500,000, individually) or when
taken together with all other Construction Contract Amendments, results in a
cost increase of $2,000,000 in the aggregate (or, with respect to the GMP
Contract only, in excess of $5,000,000 in the aggregate), (ii) when taken
together with all related Construction Contract Amendments and after giving
effect to any new, related Construction Contracts, results in a material
lessening of the scope or quality of the work constituting the design or
construction of the Facility or (iii) results in the likely addition of no less
than two weeks of construction (or such amendments, in the aggregate, result in
the likely addition of no less than eight weeks of construction) (a "MATERIAL
CONSTRUCTION CONTRACT AMENDMENT") shall be in writing and shall identify with
particularity all changes being made. Each Material Construction Contract
Amendment shall be effective when and only when: (a) the Issuer has, or the
Issuer and the Contractor have, executed and delivered the Material Construction
Contract Amendment (with the effectiveness thereof subject only to satisfaction
of the applicable conditions in clauses (b) and (c) below); (b) the Issuer has
submitted the Material Construction Contract Amendment to the Disbursement Agent
and the Trustee together with an Officer's Certificate in the form attached
hereto as EXHIBIT F (a "CONSTRUCTION CONTRACT AMENDMENT CERTIFICATE"), together
with the certificates of the Independent Construction Consultant, the General
Contractor (only for Hard Costs under the GMP Contract (including "Direct
Purchase Items" as defined in the GMP Contract), unless such Hard Costs relate
to an owner change directive issued by Premier under the GMP Contract) and
Architect (for Hard Costs with respect only to Plans prepared by it) as provided
in the form of EXHIBITS 1 through 3 to such Construction Contract Amendment
Certificate. Construction Contract Amendments which are not Material
Construction Contract Amendments shall not require compliance with the
requirements set forth in this SECTION 5.2 or the approval of the Trustee or any
other Person to be effective.

          5.3    CONSTRUCTION CONTRACTS ENTERED INTO AFTER THE ISSUANCE DATE.
The Issuer may from time to time enter into Construction Contracts consistent
with the Final Plans and the Project Budget, as each is in effect from time to
time. Each such Construction Contract shall be in writing. Each Material
Construction Contract shall become effective when and only when: (a) the Issuer
and the counterparty to such Material Construction Contract have executed and
delivered the Material Construction Contract (with the effectiveness thereof
subject only to satisfaction of the conditions in clauses (b), (c) and (d)
below); (b) the Issuer has submitted to the Trustee, with a copy to the
Disbursement Agent and the Independent Construction Consultant: (i) such
Material Construction Contract together with an Officer's Certificate in the
form attached hereto as EXHIBIT K (an "ADDITIONAL CONSTRUCTION CONTRACT
CERTIFICATE") and all exhibits, attachments and certificates required thereby,
each duly completed and executed, and (ii) copies of such performance and
payment bonds as the counterparty to such Construction Contract may be required
to provide to the Issuer pursuant to such Material Construction Contract (which
performance and payment bonds shall name the Trustee as an additional

                                       38
<Page>

obligee) and (iii) (y) and the Issuer shall use its best efforts to obtain a
consent from the counterparty (i) substantially in the form attached hereto as
EXHIBIT H-1 for Construction Contracts where the amount to be paid to the
Contractor under such Construction Contract and all related Construction
Contracts with the same Contractor exceeds $1,000,000, and (ii) substantially in
the form EXHIBIT H-2 for Construction Contracts where the amount to be paid to
the Contractor under such Construction Contract and all related Construction
Contracts with the same Contractor is between $500,000 and $1,000,000, signed by
the counterparty to such Material Construction Contract; (c) if entering into
such Material Construction Contract will result in an amendment to the Project
Budget, the Issuer has complied with the requirements of SECTION 5.1; and (d) if
entering into such Material Construction Contract will cause the Available
Construction Funds to be less than the Remaining Costs, then the Issuer,
treating such difference as a cost overrun, has complied with the requirements
of SECTION 5.4. A consent shall not be required where the amount to be paid to
the Contractor under such Construction Contract and all related Construction
Contracts with the same Contractor is less than $500,000.

          5.4    AVAILABLE CONSTRUCTION FUNDS CERTIFICATE. Concurrently with the
submission of any Construction Disbursement Request, the Issuer shall submit an
Officer's Certificate in the form of EXHIBIT D-1 (an "AVAILABLE CONSTRUCTION
FUNDS CERTIFICATE"), to the Disbursement Agent, the Trustee and the Independent
Construction Consultant. Each Available Construction Funds Certificate shall
include (i) an Available Construction Funds Schedule dated as of the first
Business Day of such month and shall set forth (A) the actual investment income
earned on the Construction Disbursement Account or the Issuer's Payment Account
through a date not more than 30 days prior to the date of the Available
Construction Funds Schedule, and (B) the Anticipated Investment Income and (ii)
either (x) shall include a certification that the amount currently on deposit in
the Tidelands Lease Account is equal to or exceeds the amount of the Tidelands
Lease Required Payment or (y) shall attach a completed Tidelands Lease
Certificate in accordance with SECTION 6.1(a).

                 5.4.1   ADDITIONAL PRE-OPERATING REVENUE. If at any time the
Issuer submits an Available Construction Funds Certificate pursuant to this
Section and the Issuer can no longer reasonably anticipate that the Additional
Pre-Operating Revenue earned (and anticipated to be earned through the date that
the Issuer reasonably anticipates that the Initial Operating Date will occur)
from investments of funds in the Construction Disbursement Account or the
Issuer's Payment Account will equal the amount of such Additional Pre-Operating
Revenue set forth in the Project Budget, then:

                 (a)     if the total amount of such Additional Pre-Operating
Revenue at such date earned or anticipated to be earned is less than the total
amount of such Additional Pre-Operating Revenue set forth in the Project Budget,
then the Available Construction Funds shall be deemed reduced by the amount of
such deficiency and the Issuer, as a condition to the next Construction
Disbursement Request, shall reallocate contingencies, provide additional
Available Construction Funds or otherwise amend the Project Budget so that the
Remaining Costs do not exceed the total Available Construction Funds; or

                 (b)     if the total amount of such Additional Pre-Operating
Revenue at such date earned or anticipated to be earned is greater than the
total amount of such Additional Pre-Operating Revenue set forth in the Project
Budget, then the Available Construction Funds shall be deemed increased by the
amount of such excess.

                                       39
<Page>

                 5.4.2   COST OVERRUNS. The Issuer covenants to cure any
anticipated cost overrun for any line item on the Project Budget (taking into
account any applicable contingencies which have been allocated to such line item
by an amendment to the Project Budget) or for the Facility as a whole within ten
days after the Issuer becomes aware of any such anticipated cost overrun by:

                 (a)     providing sufficient funds to cover in full such cost
overrun from previously unallocated Available Construction Funds or Additional
Pre-Operating Revenue (but in each case only to the extent that the same have
not previously been expended or allocated (including Retainage Amounts) to the
payment of items contained in the Project Budget); and/or

                 (b)     with respect to a cost overrun as to a particular line
item, effecting an amendment to the Project Budget to allocate such funds to the
line item in question.

          5.5    PROJECT COST SCHEDULE CERTIFICATE. The Issuer shall submit an
Officer's Certificate in the form of EXHIBIT D-2 (a "PROJECT COST SCHEDULE
CERTIFICATE") to the Independent Construction Consultant within five Business
Days following the delivery of a written request for the same by the Independent
Construction Consultant (but no more frequently than once per calendar month).
Each Project Cost Schedule Certificate shall include a Project Cost Schedule
dated as of the first Business Day of the month in which such Project Cost
Schedule Certificate is delivered and shall set forth (a) for each line item in
the Project Budget, each of the items required on EXHIBIT D-2, (b) (i) the
actual investment income earned on the Construction Disbursement Account or the
Issuer's Payment Account through a date not more than 30 days prior to the date
of the Project Cost Schedule, and (ii) the additional amount of investment
income which the Issuer reasonably anticipates will accrue on the Construction
Disbursement Account or the Issuer's Payment Account from such date through the
date that the Issuer reasonably anticipates that the Initial Operating Date will
occur and (c) a calculation certified by the Issuer of the Remaining Costs and
the Available Construction Funds as of such date. In addition, the Issuer shall
deliver to the Independent Construction Consultant any backup documentation or
other information with respect to the items on the Project Cost Schedule from
time to time as reasonably requested by the Independent Construction Consultant.

          5.6    FINAL PLANS. The Issuer shall not construct or permit to be
constructed any portion of the Facility except in substantial conformance with
the Final Plans for such portion of the Facility. The Issuer may modify the
Final Plans or cause Preliminary Plans to become Final Plans, only if such Final
Plans, as amended, or Preliminary Plans which will become Final Plans have been
delivered to the Independent Construction Consultant together with a Final Plans
Amendment Certificate in the form of EXHIBIT J delivered to the Trustee, with a
copy to the Disbursement Agent and the Independent Construction Consultant.

          5.7    NOTICE THAT PROJECT IS OPERATING. Promptly after (but in any
event within thirty days after) the Initial Operating Date of the Facility, the
Issuer shall deliver an Officers' Certificate to Disbursement Agent, the
Trustee, and the Independent Construction Consultant to the effect that the
Facility is Operating, together with a certificate from the Independent
Construction Consultant concurring with such certificate of the Issuer.

          5.8    MAINTENANCE OF PERMITTED INVESTMENTS. The Issuer shall maintain
all of its Permitted Investments in a Construction Period Account.

                                       40
<Page>

          5.9    BOND FINANCING AMOUNTS. All amounts transferred by the
Disbursement Agent from the PFC Payment Account and thereafter to the Bond
Trustee's Construction Disbursement Account pursuant to any Disbursement Request
shall be deemed to be an equity contribution by Premier to PFC. PFC shall use
such amounts solely to purchase Bonds pursuant to the Bond Financing Documents.
All amounts loaned to Premier under the Bond Financing Documents shall be used
by Premier solely to pay Permitted Land-Based Project Costs in accordance with
the Bond Financing Documents and this Disbursement Agreement.

          5.10   APPLICATION OF INSURANCE AND CONDEMNATION PROCEEDS. If any
Event of Loss shall occur with respect to the Facility or any other asset of the
Issuer, the Issuer shall (a) promptly upon discovery or receipt of notice
thereof to provide written notice thereof to the Disbursement Agent, and (b)
diligently to pursue all its rights to compensation against all relevant
insurers, reinsurers and/or governmental authorities, as applicable, in respect
of such event to the extent that the Issuer has a reasonable basis for a claim
for compensation or reimbursement, including, without limitation, under any
insurance policy required to be maintained hereunder. All amounts and proceeds
(including instruments) in respect of any Event of Loss, including the proceeds
of any insurance policy required to be maintained by the Issuer hereunder
(collectively, "LOSS PROCEEDS") shall be applied as provided in this Section.
All Loss Proceeds (other than those in respect of the FF&E Collateral which
shall be governed by the FF&E Financing documentation) shall be paid by the
insurers, reinsurers, governmental authorities or other payors directly to the
Disbursement Agent for deposit in the Construction Disbursement Account. If any
Loss Proceeds are paid directly to the Issuer, any Affiliate of the Issuer, the
Trustee or any Noteholder by any insurer, reinsurer, governmental authority or
such other payor, (i) such Loss Proceeds shall be received in trust for the
Disbursement Agent, (ii) such Loss Proceeds shall be segregated from other funds
of the Issuer or such other Person, and (iii) the Issuer or such other Person
shall pay (or, if applicable, the Issuer shall cause such of its Affiliates to
pay) such Loss Proceeds over to the Disbursement Agent in the same form as
received (with any necessary endorsement) for deposit in the Construction
Disbursement Account. Any Loss Proceeds deposited in the Construction
Disbursement Account (1) prior to the Initial Operating Date, shall be disbursed
to pay Project Costs pursuant to the requirements of SECTION 4 hereof; (2) after
the Initial Operating Date, shall be disbursed to pay for or reimburse Premier
for the actual cost of a permitted use of the Net Loss Proceeds as provided in
the Indenture; or (3) at any time, shall be applied (together with funds on
deposit in the Interest Reserve Account) to prepay or redeem the First Mortgage
Notes in accordance with the Indenture.

    6.  TIDELANDS LEASE ACCOUNT. The following covenant applies during the
Construction Period and the Operating Period:

          6.1    DEPOSITS INTO TIDELANDS LEASE ACCOUNT.

          Premier shall:

          (i) during the Construction Period concurrently with the delivery of
each Available Funds Certificate pursuant to SECTION 5.4 if the Tidelands Lease
Shortage Amount is greater than zero and within two (2) Business Days after the
Tidelands Lease Required Payment has increased: (a) deliver to the Disbursement
Agent an Officer's Certificate in the form of EXHIBIT C-6 (the "TIDELANDS LEASE
CERTIFICATE") certifying as to the amount of the Tidelands Lease Required
Payment and the Tidelands

                                       41
<Page>

Lease Shortage Amount, if any; and (b) deposit cash into the Tidelands Lease
Account an amount equal to any Tidelands Lease Shortage Amount, or submit a
Project Budget Amendment Certificate applying available contingency or Realized
Savings to fund such Tidelands Lease Shortage Amount and instruct the
Disbursement Agent in the Tidelands Lease Certificate to transfer the Tidelands
Lease Shortage Amount from the Construction Disbursement Account into the
Tidelands Lease Account.

          (ii) during the Operating Period, not later than the second (2nd)
Business Day of the month, and within two Business Days after the Tidelands
Lease Required Payment has increased: (a) deliver to the Disbursement Agent an
Officer's Certificate in the form of EXHIBIT C-6 (the "TIDELANDS LEASE
CERTIFICATE") certifying as to the amount of the Tidelands Lease Required
Payment and the Tidelands Lease Shortage Amount, if any; and (b) deposit cash
into the Tidelands Lease Account an amount equal to any Tidelands Lease Shortage
Amount, or submit a Project Budget Amendment Certificate applying available
contingency or Realized Savings to fund such Tidelands Lease Shortage Amount and
instruct the Disbursement Agent in the Tidelands Lease Certificate to transfer
the Tidelands Lease Shortage Amount from the Construction Disbursement Account
into the Tidelands Lease Account.

    7.  LIMITATION OF LIABILITY.

          7.1    LIMITATION OF DISBURSEMENT AGENT'S LIABILITY. The Disbursement
Agent's responsibility and liability under this Agreement shall be limited as
follows: (a) the Disbursement Agent does not represent, warrant or guaranty to
the Trustee or the Noteholders the performance of the Issuer, the Architect, any
Contractor or provider of materials or services in connection with construction
of the Facility; (b) the Disbursement Agent shall have no responsibility to the
Issuer, the Trustee or the Noteholders as a consequence of performance by the
Disbursement Agent hereunder except for any gross negligence or willful
misconduct of the Disbursement Agent; (c) the Issuer shall remain solely
responsible for all aspects of its business and conduct in connection with its
Site and the Facility, including, but not limited to, the quality and
suitability of the Plans, the supervision of the work of construction, the
qualifications, financial condition and performance of all architects,
engineers, contractors, subcontractors, suppliers, consultants and property
managers, the accuracy of all applications for payment, and the proper
application of all disbursements; (d) the Disbursement Agent is not obligated to
supervise, inspect or inform the Issuer, the Trustee or any third party of any
aspect of the construction of the Facility or any other matter referred to
above; and (e) the Disbursement Agent owes no duty of care to the Issuer to
protect against, or to inform the Issuer against, any negligent, faulty,
inadequate or defective design or construction of the Facility, provided that
the Disbursement Agent shall inform the Issuer if the Disbursement Agent has
Knowledge of such condition. The Disbursement Agent shall have no duties or
obligations hereunder except as expressly set forth herein (including with
respect to review of the substantive terms and conditions of any contracts
delivered to the Disbursement Agent), shall be responsible only for the
performance of such duties and obligations, shall not be required to take any
action otherwise than in accordance with the terms hereof and shall not be in
any manner liable or responsible for any loss or damage arising by reason of any
act or omission to act by it hereunder or in connection with any of the
transactions contemplated hereby, including, but not limited to, any loss that
may occur by reason of forgery, false representations, the exercise of its
discretion, or any other reason, except for its gross negligence or willful
misconduct. Copies of any Project Budget Amendment Certificate, Contract
Amendment Certificate, Final Plan Amendment

                                       42
<Page>

Certificate or Additional Contract Certificate that are provided to the
Disbursement Agent pursuant to this Agreement shall not be construed as
requiring the Disbursement Agent's approval of the Project Budget, Construction
Contract or Final Plans associated therewith. In addition, the Disbursement
Agent shall have no responsibility to inquire into or determine the genuineness,
authenticity, or sufficiency of any certificates, documents or instruments
submitted to it in connection with its duties hereunder, and shall be entitled
to deem the signatures on any such certificates, documents or instruments
submitted to it hereunder as being those purported to be authorized to sign such
certificates, documents or instruments on behalf of the parties hereto and shall
be entitled to rely upon the genuineness of the signatures of such signatories
without inquiry and without requiring substantiating evidence of any kind.

          7.2    LIMITATION OF INDEPENDENT CONSTRUCTION CONSULTANT'S LIABILITY.
The Independent Construction Consultant's responsibility and liability under
this Agreement shall be limited as follows: (a) the Independent Construction
Consultant does not represent, warrant or guaranty to the Trustee or the
Noteholders the performance of the Issuer, the Disbursement Agent, the General
Contractor, the Architect or any Contractor, subcontractor or provider of
materials or services in connection with construction of the Facility; (b)
except to the extent the Independent Construction Consultant has Knowledge, the
Independent Construction Consultant shall not be responsible for, and shall not
be obligated to make any specific inquiry with respect to, matters pertaining
to: historical architecture review, gaming regulatory authorities, gaming
licenses, liens against the Facility (except in connection with the
responsibilities of the Independent Construction Consultant set forth herein);
and (c) the Issuer shall remain solely responsible for all aspects of its
business and conduct in connection with the Facility, the accuracy of all
applications for payment, and the proper application of all disbursements. The
Independent Construction Consultant shall have no duties or obligations
hereunder, except as expressly set forth herein and in the Independent
Construction Consultant's Engagement Agreement, shall be responsible only for
the performance of such duties and obligations, shall not be required to take
any action otherwise than in accordance with the terms hereof and shall not be
in any manner liable or responsible for any loss or damage arising by reason of
any act or omission to act by it hereunder or in connection with any of the
transactions contemplated hereby, including, but not limited to, any loss that
may occur by reason of forgery, false representations, the exercise of its
discretion, or any other reason, except for its gross negligence or willful
misconduct. The Independent Construction Consultant shall have the right to rely
(so long as such reliance is reasonable and in good faith) on certificates
received from the Issuer, the Architect and the General Contractor. Anything in
this Agreement to the contrary notwithstanding, in no event shall the
Independent Construction Consultant be liable to any party hereto for any form
of special, indirect or consequential damages, including, without limitation,
damages for economic loss (such as business interruption or loss of profits,
however the same may be caused).

    8.  INDEMNITY AND INSURANCE. Each of Premier and PFC hereby indemnifies,
holds harmless and defends the Disbursement Agent and its officers, directors,
agents and employees from and against any and all claims, actions, obligations,
liabilities and expenses, including defense costs, investigative fees and costs,
legal fees, and claims for damages, arising from the Disbursement Agent's
performance under this Agreement, except to the extent that such liability,
expense or claim is attributable to the gross negligence or willful misconduct
of the Disbursement Agent. The foregoing indemnities in this paragraph shall
survive the resignation or substitution of the Disbursement Agent or the
termination of this Agreement.

                                       43
<Page>

    9.  TERMINATION. This Agreement shall terminate automatically 91 days after
the repayment and performance of all First Mortgage Note Obligations; PROVIDED,
HOWEVER, that the obligations of the Issuer under SECTION 8 of this Agreement
shall survive termination of this Agreement.

    10. SUBSTITUTION OR RESIGNATION OF THE DISBURSEMENT AGENT.

          10.1   PROCEDURE. A resignation or removal of the Disbursement Agent
and appointment of a successor Disbursement Agent shall become effective only
upon the successor Disbursement Agent's acceptance of appointment as provided in
this SECTION 10.

                 10.1.1  The Disbursement Agent may resign in writing at any
time and be discharged from all duties hereunder upon 60 days' written notice to
all parties hereto subject to this SECTION 10.1.4. The Trustee or the
Noteholders of a majority in principal amount of the then outstanding First
Mortgage Notes may remove the Disbursement Agent as provided below by so
notifying the Disbursement Agent and the Issuer in writing, if:

                 (a)     the Disbursement Agent fails to comply with
SECTION 10.3 hereof;

                 (b)     the Disbursement Agent is adjudged a bankrupt or an
insolvent or an order for relief is entered with respect to the Disbursement
Agent under any Bankruptcy Law;

                 (c)     a custodian or public officer takes charge of the
Disbursement Agent or its property; or

                 (d)     the Disbursement Agent becomes incapable of acting.

                 10.1.2  If the Disbursement Agent resigns or is removed or if a
vacancy exists in the office of Disbursement Agent for any reason, the Trustee
shall, and the Noteholders of a majority in principal amount of the then
outstanding First Mortgage Notes (if such Noteholders provided a notice pursuant
to SECTION 10.1.1 or if there is no Trustee capable of acting at such time) may,
promptly appoint a successor Disbursement Agent acceptable to the Issuer. Within
one year after any successor Disbursement Agent appointed by the Trustee takes
office, the Noteholders of a majority in principal amount of the then
outstanding First Mortgage Notes may appoint a successor Disbursement Agent
acceptable to the Issuer to replace the successor Disbursement Agent appointed
by the Trustee.

                 10.1.3  If a successor Disbursement Agent does not take office
within 60 days after the retiring Disbursement Agent resigns or is removed, the
retiring Disbursement Agent, the Trustee, the Issuer or the Noteholders of at
least 10% in principal amount of the then outstanding First Mortgage Notes may
petition any court of competent jurisdiction for the appointment of a successor
Disbursement Agent.

                 10.1.4  A successor Disbursement Agent shall deliver a written
acceptance of its appointment to the retiring Disbursement Agent, the Issuer and
the Trustee. Thereupon, the resignation or removal of the retiring Disbursement
Agent shall become effective, and the successor Disbursement Agent shall have
all the rights, powers and duties of the Disbursement Agent under this
Agreement. The retiring Disbursement Agent shall promptly transfer all property
held by it as Disbursement Agent to the successor Disbursement Agent.

                                       44
<Page>

          10.2   SUCCESSOR DISBURSEMENT AGENT BY MERGER, ETC. If the
Disbursement Agent consolidates, merges or converts into, or transfers all or
substantially all of its corporate trust business to, another corporation, the
successor corporation without any further act shall be the successor
Disbursement Agent.

          10.3   ELIGIBILITY; DISQUALIFICATION. The Disbursement Agent shall at
all times be a bank chartered under the laws of the United States of America or
of any state thereof that is authorized under such laws to exercise corporate
trust power, that is subject to supervision or examination by federal or state
authorities and that has a combined capital and surplus of at least $100 million
as set forth in its most recent published annual report of condition and a
Thomson's Bank Watch rating of AA- or better.

          10.4   CONSENT OF INDEPENDENT CONSTRUCTION CONSULTANT. The Independent
Construction Consultant acknowledges and agrees that the Trustee shall have the
right to change the party acting as the "Disbursement Agent" pursuant to this
Agreement, and the Trustee agrees to provide written notice to the Independent
Construction Consultant of any such change.

    11.   INDEPENDENT CONSTRUCTION CONSULTANT.

          11.1   REMOVAL AND FEES. Only the Trustee in its sole discretion may
remove the Independent Construction Consultant from time to time and upon such
removal a replacement acceptable to the Trustee shall be appointed in
consultation with the Issuer (unless an Event of Default exists). Notice of any
replacement Independent Construction Consultant shall be given by the Trustee to
the Disbursement Agent, the Issuer and the Independent Construction Consultant
being replaced. All reasonable fees and expenses of the Independent Construction
Consultant (whether the original ones or replacements) shall be paid by the
Issuer. Neither the Disbursement Agent nor the Issuer shall have the right to
remove the Independent Construction Consultant or appoint a replacement. The
Issuer is a party to the Independent Construction Consultant's Engagement
Agreement and hereby agrees to timely pay all fees of the Independent
Construction Consultant set forth therein in accordance with the terms thereof.

          11.2   DUTIES. The Independent Construction Consultant shall be
contractually obligated to the Trustee to carry out the activities required of
it in this Agreement and in the Construction Consultant Engagement Agreement and
as otherwise requested by the Trustee, the Issuer, and the Disbursement Agent.
Trustee shall remove Independent Construction Consultant at request of Issuer if
Issuer determines that Independent Construction Consultant is incompetent or
failed to perform a material obligation under this Agreement or the Independent
Construction Consultant's Engagement Agreement.

          11.3   ACTS OF DISBURSEMENT AGENT. The Disbursement Agent will take
such actions as the Trustee or the Issuer may reasonably request to cause the
Independent Construction Consultant to act diligently in the issuance of all
certificates required to be delivered by the Independent Construction Consultant
hereunder and to otherwise fulfill their obligations to the Trustee as described
in the first sentence of SECTION 10.2.

    12.   STATEMENT OF SECURITIES ACCOUNTS. Upon the request of the Issuer or
the Trustee from time to time, the Disbursement Agent shall deliver to the
Issuer and the Trustee an account statement prepared by the Disbursement Agent
in a form satisfactory to the Trustee and the

                                       45
<Page>

Issuer setting forth with reasonable particularity the balance of funds then in
the Securities Accounts and the manner in which such funds are invested;
PROVIDED, HOWEVER, that the Disbursement Agent shall not be required to provide
such statements more often than weekly. The parties hereto irrevocably instruct
the Disbursement Agent that on the first date upon which the balance in any
Securities Account is reduced to zero, the Disbursement Agent shall deliver to
the Trustee and the Issuer a notice that the balance in such Securities Account
has been reduced to zero.

    13.   MISCELLANEOUS.

          13.1   WAIVER. Any party hereto may specifically waive any breach of
this Agreement by any other party, but no such waiver shall be deemed to have
been given unless such waiver is in writing, signed by the waiving party and
specifically designates the breach waived, nor shall any such waiver constitute
a continuing waiver of similar or other breaches.

          13.2   INVALIDITY. If, for any reason whatsoever, any one or more of
the provisions of this Agreement shall be held or deemed to be inoperative,
unenforceable or invalid in a particular case or in all cases, such
circumstances shall not have the effect of rendering any of the other provisions
of this Agreement inoperative, unenforceable or invalid, and the inoperative,
unenforceable or invalid provision shall be construed as if it were written so
as to effectuate, to the maximum extent possible, the parties' intent.

          13.3   NO AUTHORITY. The Disbursement Agent shall not have any
authority to, and shall not make any warranty or representation or incur any
obligation on behalf of, or in the name of, the Trustee.

          13.4   ASSIGNMENT. This Agreement is personal to the parties hereto,
and the rights and duties of any party hereunder shall not be assignable except
with the prior written consent of the other parties. In any event, this
Agreement shall inure to and be binding upon the parties and their successors
and permitted assigns.

          13.5   BENEFIT. The parties hereto and their respective successors and
assigns, but no others, shall be bound hereby and entitled to the benefits
hereof.

          13.6   TIME. Time is of the essence of each provision of this
Agreement.

          13.7   ENTIRE AGREEMENT; AMENDMENTS. This Agreement (together with the
Indenture and the Collateral Documents) contains the entire agreement among the
parties hereto with respect to the subject matter hereof and supersedes any and
all prior agreements, understandings and commitments, whether oral or written.
This Agreement may be amended only by a writing signed by duly authorized
representatives of all parties.

          13.8   NOTICES. All notices and other communications required or
permitted to be given or made under this Agreement shall be in writing and shall
be deemed to have been duly given and received, regardless of when and whether
received, either: (a) on the day of hand delivery; or (b) on the day sent, when
sent by United States certified mail, postage and certification fee prepaid,
return receipt requested; or by facsimile transmission, in each case, addressed
as follows:

                                       46
<Page>

          To the Disbursement Agent:

          U.S. Bank National Association
          60 Livingston Avenue
          St. Paul, MN 55107-2292
          Attn: Frank Leslie
          Telephone No.:  (651) 495-3913
          Telecopy No.:  (651) 495-8097

          To the Trustee:

          U.S. Bank National Association,
          60 Livingston Avenue
          St. Paul, MN 55107-2292
          Attn: Frank Leslie
          Telephone No.:  (651) 495-3913
          Telecopy No.:  (651) 495-8097

          To the Issuer:

          Premier Entertainment Biloxi LLC
          11400 Reichold Road
          Gulfport, Mississippi 39503
          Telecopy No.: (228) 594-4021
          Telephone No.: (228) 896-4078
          Attn: Joseph Billhimer

          with a copy to:

          Balch & Bingham LLP
          1310 Twenty Fifth Avenue
          Gulfport, Mississippi 39501
          Telephone:  (228) 214-0411
          Facsimile:  (888) 506-8674
          Attention:  Ricky J. Cox, Esquire

          with a further copy to:

          Duane Morris LLC
          227 West Monroe Street, Suite 3400
          Chicago, Illinois 60606
          Attention:  Brian P. Kerwin, Esq.
          Telephone:  (312) 499-6737
          Facsimile:  (312) 499-6701

          To the Independent Construction Consultant:

          Professional Associates Construction Services
          942 East Chapman Avenue
          Orange, California 92866

                                       47
<Page>

          Attention: Kent Robertson
          Telephone: (714) 289-2330
          Facsimile: (714) 289-2979

          To the Issuing Agent:

          Balch & Bingham LLP
          1310 Twenty Fifth Avenue
          Gulfport, Mississippi 39501
          Telephone:  (228) 864-9900
          Facsimile: (228) 864-8221
          Attention:     Jennifer Signs, Esq.
                         email:  jsigns@balch.com
                         Rodger Wilder, Esq.
                         email:  rwilder@balch.com
                         Luther Boyd, Esq.
                         email:  lboyd@balch.com

or at such other address as the specified entity most recently may have
designated in writing in accordance with this SECTION 13.8 to the others.

          13.9   COUNTERPARTS. This Agreement may be executed in one or more
counterparts, each of which shall be deemed an original but all of which
together shall constitute one and the same instrument.

          13.10  CAPTIONS. Captions in this Agreement are for convenience only
and shall not be considered or referred to in resolving questions of
interpretation of this Agreement.

          13.11  RIGHT TO CONSULT COUNSEL. Each of the Disbursement Agent and
the Trustee may, if any of them deems necessary or appropriate, consult with and
be advised by counsel (whether such counsel shall be regularly retained or
specifically employed) in respect of their duties hereunder. Each of the
Disbursement Agent or the Trustee shall be entitled to reasonably rely upon the
advice of its counsel in any action taken in its capacity as the Disbursement
Agent or the Trustee, as the case may be, hereunder and shall be protected from
any liability of any kind for actions taken in reasonable reliance upon such
opinion of its counsel. The Issuer agrees to pay all such reasonable counsel
fees actually incurred.

          13.12  CHOICE OF LAW. This Agreement shall be governed by and
construed in accordance with the laws of the State of New York including without
limitation, SECTION 5-1401 of the New York General Obligations Law; PROVIDED,
HOWEVER, that with respect to the creation, attachment, perfection or priority
of the security interest in any Collateral, the governing law shall be the
applicable UCC as set forth in the definition of the term "UCC".

          13.13  DESIGNATION OF APPLICABLE COURTS AND JURISDICTIONS. Each of
Premier and PFC hereby irrevocably consents to the following courts,
jurisdictions and venues for the judicial action described in SECTION 13.12
above (the "APPLICABLE COURTS"): (a) the United States District Court for the
Southern District of New York, and all courts to which any appeal therefrom may
be available; (b) any court of the State of New York, and all courts to which
any appeal

                                       48
<Page>

therefrom may be available; and (c) if none of the foregoing courts shall have
or accept jurisdiction, then any other federal or state court, and all courts to
which any appeal therefrom may be available.

          13.14  SURETYSHIP WAIVERS. Each of Premier and PFC hereby waives any
and all defenses available to a surety or guarantor, whether arising as a result
of the joint and several liability hereunder or otherwise. Without limiting the
generality of the foregoing, the waivers of the guarantors under SECTION 13.01
of the Indenture are hereby incorporated herein by this reference mutatis
mutandis and such waivers shall be deemed to be made by Premier and PFC
hereunder as if such waivers had been expressly set forth herein.

                  [REMAINDER OF PAGE INTENTIONALLY LEFT BLANK]

                                       49
<Page>

     IN WITNESS WHEREOF, the parties hereto have each caused this Agreement to
be duly executed by their duly authorized officers, all as of the day and year
first above written.

                                   U.S. BANK NATIONAL ASSOCIATION, a
                                   national banking association, as Disbursement
                                   Agent

                                   By: /s/ Frank P. Leslie
                                      ------------------------------------------
                                      Name: Frank P. Leslie
                                      Title: Vice President

                                   U.S. BANK NATIONAL ASSOCIATION, a
                                   national banking association, as Trustee

                                   By: /s/ Frank P. Leslie
                                      ------------------------------------------
                                      Name: Frank P. Leslie
                                      Title: Vice President

                                   PREMIER ENTERTAINMENT BILOXI LLC,
                                   a Delaware limited liability company

                                   By: /s/ Joseph Billhimer
                                      ------------------------------------------
                                      Name: Joseph Billhimer
                                      Title: President and COO

                                   PREMIER FINANCE BILOXI CORP.,
                                   a Delaware corporation

                                   By: /s/ Joseph Billhimer
                                      --------------------------------------
                                      Name: Joseph Billhimer
                                      Title: President and COO

                                   PROFESSIONAL ASSOCIATES
                                   CONSTRUCTION SERVICES, INC.
                                   a California corporation

                                   By: /s/ Kent Robertson
                                      ------------------------------------------
                                      Name: Kent Robertson
                                      Title: Secretary-Treasurer

<Page>

             EXHIBIT A TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
                        INITIAL DISBURSEMENTS CERTIFICATE

                                January 23, 2004

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

          Re:  Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance
               Biloxi Corp. ("PFC", and jointly and severally with Premier, the
               "ISSUER") Cash Collateral and Disbursement Agreement
                Initial Construction Disbursements

Ladies and Gentlemen:

               This Initial Disbursements Certificate is delivered to you
pursuant to SECTION 4.1 of that certain Cash Collateral and Disbursement
Agreement dated as of January 23, 2004 (the "AGREEMENT"). Capitalized terms used
herein shall have the meanings assigned to such terms in the Agreement.

          The Issuer hereby irrevocably instructs the Disbursement Agent to
disburse the following sums from the Construction Disbursement Account to the
following parties:

          (a)  (i) transfer $115,415.18 from the Construction Disbursement
Account (U.S. Bank, N.A. Account No. 744829001) to the PFC Payment Account (U.S.
Bank, N.A. Account No. 744829004; which shall be deemed to be an equity
contribution to PFC); and (ii) immediately after such funds have been
transferred into the PFC Payment Account, transfer such funds from the PFC
Payment Account to the Bond Trustee's Construction Disbursement Account (U.S.
Bank, N.A. Account No. 744829009), and disburse such amounts from the Bond
Trustee's Construction Disbursement Account to the following parties for payment
of cost of issuance fees relating to the Bonds:

<Table>
               <S>                                           <C>
               Mississippi Business Finance Corp.            $   40,000.00
               Watkins, Ludlam, Winter & Stennis, P.A.       $   61,415.18
               Holley Grubbs, Mitcham & Phillips             $    9,000.00
               Balch & Bingham LLP                           $    5,000.00
</Table>

          (b)  (i) transfer $500,000.00 from the Construction Disbursement
Account (U.S. Bank, N.A. Account No. 744829001) to the PFC Payment Account (U.S.
Bank, N.A. Account No. 744829004; which shall be deemed to be an equity
contribution to PFC); and (ii) immediately

                                   Page 1 of 4
                                    EXHIBIT A
<Page>

after such funds have been transferred into the PFC Payment Account, transfer
such funds from the PFC Payment Account to the Company's Direct Disbursement
Account (U.S. Bank, N.A. Account No. 744829010);

          (c)  $2,218,068.50 TO THE GENERAL CONTRACTOR (ROY ANDERSON CORP.) for
payment of the following amounts under the GMP Contract:

<Table>
               <S>                                           <C>
               Mobilization fee                              $   75,000.00
               Balance of Required Commencement Deposit
               for Corn Island Shipyard, Inc.                $  175,830.50
               Pre-Construction (general conditions) Costs   $  126,471.00
               Reigstad and Associates, Inc.                 $  125,000.00
               General Contractor's Performance Bond         $  614,679.00
               Contractor's Insurance                        $  893,333.00
               Building Permit                               $  164,579.00
               Corn Island Performance Bond                  $   43,176.00
</Table>

          (d)  $671,447.82 TO THE ARCHITECT (PAUL STEELMAN LTD.), as payment of
certain fees incurred under the Architectural Services Agreement for payment of
design and construction drawings;

          (e)  $16,875.00 TO THE INDEPENDENT CONSTRUCTION CONSULTANT
(PROFESSIONAL ASSOCIATES CONSTRUCTION SERVICES), as compensation payable to the
Independent Construction Consultant pursuant to SECTION 3.3 of the Agreement for
the first month after the Issuance Date;

          (f)  $650,000.00 TO DUANE MORRIS LLP, as payment of certain legal fees
incurred in connection with the issuance of the First Mortgage Notes;

          (g)  $425,000.00 TO BALCH & BINGHAM LLP, as payment of certain legal
fees undertaken in connection with the issuance of the First Mortgage Notes;

          (h)  $213,486.45 TO BALCH & BINGHAM LLP, as Issuing Agent for First
American Title Insurance Company, as Title Insurer, as payment of real estate
taxes incurred in connection with the Site;

          (i)  $168,000.00 TO BALCH & BINGHAM LLP, as Issuing Agent for First
American Title Insurance Company, as Title Insurer, as payment of title
insurance premiums for the Trustee's Title Policies; and

          (j)  $150.00 TO BALCH & BINGHAM LLP, as Issuing Agent for First
American Title Insurance Company, as Title Insurer, as payment of recording fees
incurred in connection with the recordation of certain Transaction Documents.

                                   Page 2 of 4
                                    EXHIBIT A
<Page>

          (k)  $59,505.57 TO LATHAM & WATKINS LLP, as payment of certain legal
fees incurred in connection with the issuance of the First Mortgage Notes;

          (l)  $13,333.33 TO HARD ROCK CAFE INTERNATIONAL, as payment of
technical service fee pursuant to the Hard Rock License Agreement;

          (m)  $298,053.42 TO MERRILL CORP., as payment of printing costs
incurred in connection with the issuance of the First Mortgage Notes;

          (n)  $80,851.23 TO BANK OF AMERICA, as payment of certain road show
expenses incurred in connection with the issuance of the First Mortgage Notes;
and

          (o)  $131,250.00 TO AON, as payment of D&O insurance coverage.

          THE TOTAL AMOUNT OF DISBURSEMENTS REQUESTED BY THIS INITIAL
DISBURSEMENTS CERTIFICATE IS $5,561,436.50.

          Premier Finance Biloxi Corp., a Delaware corporation, hereby confirms
that the conditions precedent set forth in SECTION 8 of the Bond Purchase
Contract have been satisfied or waived. The amounts transferred to the Bond
Trustee's Construction Disbursement Account shall be used solely for the purpose
of purchasing Bonds and paying Permitted Land-Based Project Costs as identified
on the copy of the Bond Requisition attached hereto as Exhibit 1 in accordance
with the Bond Financing Documents. The amounts transferred to the Company's
Direct Disbursement Account shall be used solely for the purpose of purchasing
Bonds and paying Permitted Land-Based Project Costs from time to time in
accordance with the Bond Financing Documents.

          The Disbursement Agent is entitled to rely on the foregoing
representations, warranties and certifications in authorizing and making the
disbursements requested by this Initial Disbursements Certificate.

                            [SIGNATURE PAGE FOLLOWS]

                                   Page 3 of 4
                                    EXHIBIT A
<Page>

     IN WITNESS WHEREOF, the undersigned has executed this Initial Disbursement
Certificate as of this 23rd day of January, 2004.

                              PREMIER ENTERTAINMENT BILOXI LLC,
                              on behalf of itself and Premier Finance Biloxi
                              Corp., as Issuer

                              By:
                                 --------------------------------------------
                              Name:   Joseph Billhimer
                              Title:  President/Chief Operating Officer

                              PREMIER FINANCE BILOXI CORP.

                              By:
                                 --------------------------------------------
                              Name:   Joseph Billhimer
                              Title:  President

                                   Page 4 of 4
                                    EXHIBIT A
<Page>

                             EXHIBIT 1 TO EXHIBIT A

                                BOND REQUISITION

                       [ISSUER TO ATTACH COPY OF COMPLETED
                            INITIAL BOND REQUISITION]

                                   Page 1 of 1
                             EXHIBIT 1 TO EXHIBIT A
<Page>

            EXHIBIT B-1 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
                     FORM OF ISSUER'S CLOSING CERTIFICATION

                                __________, 20__

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Re:  Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance Biloxi
     Corp. ("PFC", and jointly and severally with Premier, the "ISSUER")
     Cash Collateral and Disbursement Agreement
     Issuer's Closing Certification

Ladies and Gentlemen:

     This Issuer's Closing Certification is delivered to you pursuant to SECTION
4.1 of that certain Cash Collateral and Disbursement Agreement dated as of
January 23, 2004 (the "AGREEMENT"). Capitalized terms used herein shall have the
meanings assigned to such terms in the Agreement.

     The Issuer hereby certifies to you as follows:

     (a)  As of the date hereof, we believe the Initial Operating Date will
occur on or prior to the Operating Deadline.

     (b)  The Initial Project Budget attached hereto as EXHIBIT 1 constitutes
the Project Budget presently in effect for the Facility.

     (c)  The Remaining Budget Amount Column of the Initial Project Budget
accurately sets forth in all material respects the anticipated Construction
Expenses through the Initial Operating Date and the various components of the
Facility identified thereon as line items, all within the respective line item
allocations established for those components set forth in the Initial Project
Budget.

     (d)  The Remaining Budget Amount Column of the Initial Project Budget also
accurately sets forth in all material respects all anticipated Pre-Opening
Expenses which the Issuer will need to incur in order for the Initial Operating
Date to occur on or prior to the Operating Deadline, all within the line item
allocations established for those components set forth in the Initial Project
Budget.

     (e)  As of the date hereof, there are sufficient Available Construction
Funds to pay for the anticipated costs described in Paragraphs (b) and (c)
above, and, after giving effect to the Initial Disbursements, the Issuer does
not believe that any other material expenses will need to be incurred by the
Issuer in order to cause the Initial Operating Date to occur on or prior to the
Operating Deadline.

                                   Page 1 of 4
                                   EXHIBIT B-1
<Page>

     (f)  Attached hereto as EXHIBIT 2 is (i) a list of all contractors,
subcontractors, suppliers and materialmen that have provided work, supplies
and/or labor in connection with the construction of the Facility to date, (ii) a
list of all contractors, subcontractors, suppliers and materialmen that have
provided work, supplies and/or labor in connection with the Facility that will
receive payment pursuant to the Initial Disbursements Certificate, and (iii)
lien releases, affidavits and agreements in the form specified by EXHIBITS M-1,
M-2 and M-3 from Owner and each Contractor identified in the Initial
Disbursements Certificate for payment of Project Costs and otherwise in form and
substance reasonably satisfactory to the Independent Construction Consultant
(PROVIDED, HOWEVER, lien releases, affidavits and agreements need not be
provided from a single Contractor with a contract price (or expected aggregate
amount to be paid in the case of "cost plus" contracts) of less than $100,000).
All work performed and materials delivered to date with respect to the Facility
which could result in a lien against the Facility have been previously paid for
by the Issuer or will be timely paid for with the proceeds of the Initial
Disbursements (in each case subject to withheld Retainage Amounts), and no lien,
notice of lien, or notice of extension of time for filing of lien has been filed
against the Facility in favor of any contractor, subcontractor, supplier or
materialman which has not been removed of record prior to the date hereof.

     (g)  EXHIBIT 3 lists all Construction Contracts entered into as of the date
hereof. The Issuer has delivered copies of all such Construction Contracts that
are Material Construction Contracts (together with, for each such Material
Construction Contract, if and to the extent required under SECTION 5.3 of the
Agreement a consent in the form attached to the Agreement and copies of any
applicable performance and payment bonds required under SECTION 4.2.2(C) of the
Agreement) to the Disbursement Agent and the Independent Construction
Consultant.

     (h)  The Issuer is not and, to the Issuer's Knowledge, no other party to
any Transaction Document or Material Construction Contract (other than any
Transaction Document or Material Construction Contract not in existence as of
the Issuance Date) is, or (but for the passage of time or the giving of notice
or both) will be, in breach of any material obligation thereunder.

     (i)  The Preliminary Plans for the Facility as of the date hereof are
described on EXHIBIT 4 and the Final Plans for the Facility as of the date
hereof are described on EXHIBIT 5. All of such Final Plans:

          (i)    have received all approvals from all governmental authorities
     required to approve such Plans that are necessary to commence construction
     of such work or improvements described therein;

          (ii)   contain sufficient specificity to permit completion of such
     work or improvement described therein;

          (iii)  are consistent with constructing the Facility to include the
     Minimum Facilities;

          (iv)   have been signed by an architect licensed to practice
     architecture in the State of Mississippi;

                                   Page 2 of 4
                                   EXHIBIT B-1
<Page>

          (v)    call for construction of the Facility in a manner consistent
     with the Initial Operating Date occurring on or prior to the Operating
     Deadline; and

          (vi)   have been delivered to the Disbursement Agent.

     (j)  The only Applicable Permits that will be required for the construction
of the Facility and the operation of the Facility (as of the Initial Operating
Date) are listed on EXHIBIT 9 attached hereto (the "AGREED PERMITS").

     (k)  Each representation and warranty of (i) the Issuer set forth in the
Agreement or in any of the other Transaction Documents, or in any certificates
delivered in connection with any of the foregoing, is true, correct and complete
in all material respects as if made on the date hereof (except that any
representation and warranty that relates expressly to an earlier date shall be
deemed made only as of such earlier date), and (ii) the General Contractor, the
Independent Construction Consultant, the Architect and each other party (other
than the Issuer) to a Material Construction Contract set forth in its respective
Material Construction Contract, is, to the Issuer's Knowledge, true, correct and
complete in all material respects as if made on the date hereof (except that any
representation and warranty that relates expressly to an earlier date shall be
deemed made only as of such earlier date).

     (l)  The Transaction Documents required under applicable law to have been
approved by the Mississippi Gaming Commission have been approved by the
Mississippi Gaming Commission, and Premier has obtained all necessary approvals
of its site development plan.

     (m)  No Event of Default exists.

          The Disbursement Agent is entitled to rely on the foregoing
representations, warranties and certifications in authorizing and making the
Initial Disbursements.

     Attached to this Issuer's Closing Certification as EXHIBITS 6 through 8 are
certificates from the General Contractor, the Independent Construction
Consultant and Architect.

                           PREMIER ENTERTAINMENT BILOXI LLC,
                           on behalf of itself and Premier Finance Biloxi Corp.,
                           as Issuer

                           By:
                              -------------------------------------------------
                           Name:
                           Title:

                                   Page 3 of 4
                                   EXHIBIT B-1
<Page>

                            EXHIBIT 1 TO EXHIBIT B-1
                             INITIAL PROJECT BUDGET

                                   Page 1 of 1
                            EXHIBIT 1 TO EXHIBIT B-1
<Page>

                            EXHIBIT 2 TO EXHIBIT B-1
              LIST OF CONTRACTORS, SUBCONTRACTORS AND LIEN RELEASES

                                   Page 1 of 1
                            EXHIBIT 2 TO EXHIBIT B-1
<Page>

                            EXHIBIT 3 TO EXHIBIT B-1
                         LIST OF CONSTRUCTION CONTRACTS

                                   Page 1 of 1
                            EXHIBIT 3 TO EXHIBIT B-1
<Page>

                            EXHIBIT 4 TO EXHIBIT B-1
                                PRELIMINARY PLANS

                                   Page 1 of 1
                            EXHIBIT 4 TO EXHIBIT B-1
<Page>

                            EXHIBIT 5 TO EXHIBIT B-1
                                   FINAL PLANS

                                   Page 1 of 1
                            EXHIBIT 5 TO EXHIBIT B-1
<Page>

                            EXHIBIT 6 TO EXHIBIT B-1
                    FORM OF GENERAL CONTRACTOR'S CERTIFICATE

                                 _________, 20__

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

          Re:  Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance
               Biloxi Corp. ("PFC", and jointly and severally with Premier, the
               "ISSUER") Cash Collateral and Disbursement Agreement
               Issuer's Closing Certification dated __________, 20__

Ladies and Gentlemen:

     Roy Anderson Corp (the "GENERAL CONTRACTOR"), hereby certifies to each of
you as follows:

     (a)  The General Contractor has reviewed the above referenced Issuer's
Closing Certification from the Issuer and the Cash Collateral and Disbursement
Agreement dated as of January 23, 2004 (the "AGREEMENT"), to which the Issuer is
a party, to the extent necessary to understand the defined terms contained
herein and in the Issuer's Closing Certification that are incorporated by
reference from the Agreement, and to provide the certification contained herein.
Capitalized terms used herein and not otherwise defined shall have the meanings
ascribed to them in the Agreement.

     (b)  The General Contractor hereby certifies and confirms that it believes
that, with respect to that portion of the Facility to be constructed pursuant to
the GMP Contract entered into by the General Contractor, the Initial Operating
Date will occur on or prior to the Operating Deadline.

     (c)  The General Contractor hereby certifies that to the best of its
Knowledge, the Facility with the Minimum Facilities may be constructed in
accordance within the Initial Project Budget identified in Issuer's Closing
Certification.

                                   Page 1 of 2
                            EXHIBIT 6 TO EXHIBIT B-1
<Page>

     (d)  The list of contractors, subcontractors and suppliers and materialmen
in EXHIBIT 2 to Issuer's Closing Certificate: (i) relating to the GMP Contract
(including the "Direct Purchase Items" as defined in the GMP Contract) are true
and accurate; and (ii) relating to any other Construction Contracts are, to the
General Contractor's Knowledge, true and accurate.

     (e)  The list of Construction Contracts in EXHIBIT 3 to the Issuer's
Closing Certificate: (i) relating to the GMP Contract (including the "Direct
Purchase Items" as defined in the GMP Contract) are true, accurate and complete;
and (ii) relating to any other Construction Contracts are, to the General
Contractor's Knowledge, true, accurate and complete.

     (f)  The General Contractor is not and, to the General Contractor's
Knowledge, Premier is not, or (but in the passage of time or giving of notice or
both) will not be, in breach of any material obligation under any Construction
Contract.

     (g)  The only Applicable Permits that will be required for the construction
of the Facility are listed on EXHIBIT 9 to the Issuer's Closing Certificate. The
General Contractor expresses no opinion as to the permits required for the
operation of the Facility.

                                    ROY ANDERSON CORP

                                    By:
                                       -----------------------------------------
                                    Name:
                                    Title:

                                   Page 2 of 2
                            EXHIBIT 6 TO EXHIBIT B-1
<Page>

                            EXHIBIT 7 to EXHIBIT B-1
            FORM OF INDEPENDENT CONSTRUCTION CONSULTANT'S CERTIFICATE

                                __________, 20__

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

          Re:  Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance
               Biloxi Corp. ("PFC", and jointly and severally with Premier, the
               "ISSUER") Cash Collateral and Disbursement Agreement
               Issuer's Closing Certification dated __________, 20__

Ladies and Gentlemen:

     Professional Associates Construction Associates, Inc. (the "INDEPENDENT
CONSTRUCTION CONSULTANT") hereby certifies to each of you as follows:

          (a)  The Independent Construction Consultant has reviewed the above
referenced Issuer's Closing Certification from the Issuer and the Cash
Collateral and Disbursement Agreement dated as of January 23, 2004 (the
"AGREEMENT"), to which the Issuer is a party, to the extent necessary to
understand the defined terms contained herein and in Issuer's Closing
Certification that are incorporated by reference from the Agreement, and to
provide the certification contained herein. Capitalized terms used herein and
not otherwise defined shall have the meanings ascribed to them in the Agreement.

     (b)  The Independent Construction Consultant hereby certifies and confirms
in its professional opinion after due inquiry and investigation, that the
certifications in Paragraphs (b) and (c) of the above-referenced Issuer's
Closing Certification are accurate.

     (c)  The Independent Construction Consultant hereby certifies and confirms
to the best of its Knowledge after due inquiry and investigation, the
certifications in Paragraphs (g) and (i) of the above-referenced Issuer's
Closing Certification are accurate.

     (d)  The Independent Construction Consultant hereby acknowledges receipt of
the lien releases, affidavits and agreements from Premier and each Contractor
required by clause (f)(iii)

                                   Page 1 of 2
                            EXHIBIT 7 to EXHIBIT B-1
<Page>

of the Issuer's Closing Certification and confirms that the amounts requested to
be paid to such Contractors are appropriately and accurately reflected in the
Issuer's Closing Certification and such lien releases.

     (e)  The Independent Construction Consultant hereby certifies that, to the
best of its Knowledge, the Facility with the Minimum Facilities may be
constructed in accordance within the Initial Project Budget identified in the
Issuer's Closing Certification.

     (f)  After reviewing the documentation provided by the Issuer and the
General Contractor with respect to Agreed Permits, the Independent Construction
Consultant believes that such documentation evidences that the Issuer has
performed a commercially reasonable and diligent analysis and has no reason to
believe that the certification with regard to the Agreed Permits required for
the construction of the Facility contained in paragraph (j) of the
above-referenced Issuer's Closing Certification is materially false or
misleading.

     The Disbursement Agent and the Issuer are entitled to rely on the foregoing
representations, warranties and certifications in connection with the Initial
Disbursements.

                                            PROFESSIONAL ASSOCIATES CONSTRUCTION
                                            SERVICES, INC.

                                            By:
                                               ---------------------------------
                                            Name:
                                            Title:

                                   Page 2 of 2
                            EXHIBIT 7 to EXHIBIT B-1
<Page>

                            EXHIBIT 8 TO EXHIBIT B-1
                         FORM OF ARCHITECT'S CERTIFICATE

                                __________, 20__

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

          Re:  Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance
               Biloxi Corp. ("PFC", and jointly and severally with Premier, the
               "ISSUER") Cash Collateral and Disbursement Agreement
               Issuer's Closing Certification dated __________, 20__

Ladies and Gentlemen:

     Paul Steelman, Ltd. (the "ARCHITECT") hereby certifies to each of you as
follows;

     (a)  The Architect has reviewed the above referenced Issuer's Closing
Certification from the Issuer and the Cash Collateral and Disbursement Agreement
dated as of January 23, 2004 (the "AGREEMENT"), to which the Issuer is a party,
to the extent necessary to understand the defined terms contained herein and in
Issuer's Closing Certification that are incorporated by reference from the
Agreement, and to provide the certification contained herein. Capitalized terms
used herein and not otherwise defined shall have the meanings ascribed to them
in the Agreement.

     (b)  The Architect hereby certifies and confirms that the Plans described
on EXHIBIT 5 to the Issuer's Closing Certification:

          (i)    have received all approvals from all governmental authorities
                 required to approve such Plans that are necessary to commence
                 construction of such work or improvements, if any, described
                 therein;

          (ii)   contain sufficient specificity to permit completion of the work
                 or improvement described therein;

                                   Page 1 of 2
                            EXHIBIT 8 to EXHIBIT B-1
<Page>

          (iii)  are consistent with constructing the Facility to include the
                 Minimum Facilities; and

          (iv)   have been signed by an architect licensed to practice
                 architecture in the State of Mississippi.

     The Architect hereby certifies and confirms in its professional opinion
after due inquiry and investigation, that the certifications in Paragraphs (a),
(c) and (j) of the above-referenced Issuer's Closing Certification are accurate.

     The Disbursement Agent and the Issuer are entitled to rely on the foregoing
representations, warranties and certifications in connection with the Initial
Disbursements.

                                            PAUL STEELMAN, LTD.

                                            By:
                                               ---------------------------------
                                            Name:
                                            Title:

                                   Page 2 of 2
                            EXHIBIT 8 to EXHIBIT B-1
<Page>

                            EXHIBIT 9 TO EXHIBIT B-1
                             AGREED PERMITS SCHEDULE

                           CONSTRUCTION PERIOD PERMITS

                                   Page 1 of 2
                            EXHIBIT 9 TO EXHIBIT B-1
<Page>

                            OPERATION PERIOD PERMITS

                                   Page 2 of 2
                            EXHIBIT 9 to EXHIBIT B-1
<Page>

            EXHIBIT B-2 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
                     FORM OF TRUSTEE'S CLOSING CERTIFICATION

                                __________, 20__

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

          Re:  Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance
               Biloxi Corp. ("PFC", and jointly and severally with Premier, the
               "ISSUER") Cash Collateral and Disbursement Agreement
               Issuer's Closing Certification dated __________, 20__

Ladies and Gentlemen:

     This Trustee's Closing Certification is delivered to each of you pursuant
to that certain Cash Collateral and Disbursement Agreement dated as of January
23, 2004 (the "AGREEMENT"). Capitalized terms used herein shall have the
meanings assigned to such terms in the Agreement.

     U.S. Bank National Association, a national banking association (the
"TRUSTEE") hereby certifies to each of you as follows as contemplated by SECTION
4.1(C) of the Agreement that the Trustee has received from the Issuer an
executed Initial Disbursements Certificate and an executed Issuer's Closing
Certification in the form attached to the Agreement as EXHIBIT B-1, together
with closing certifications from the General Contractor, the Independent
Construction Consultant, the Architect, and the other required attachments to
the Issuer's Closing Certification, each in the form called for thereby.

     The Disbursement Agent and the Issuer are entitled to rely on the foregoing
representations, warranties and certifications in connection with the Initial
Disbursements; provided that where any certification of the Issuer, the General
Contractor, the Independent Constructor Consultant or the Architect is limited
to such party's Knowledge, for the purposes of this certificate, such
certification shall instead be made to the Trustee's Knowledge, as applicable.

                                   Page 1 of 2
                                   EXHIBIT B-2
<Page>

                                            U.S. BANK NATIONAL ASSOCIATION, A
                                            NATIONAL BANKING ASSOCIATION

                                            By:
                                               ---------------------------------
                                            Name:
                                            Title:

                                   Page 2 of 2
                                   EXHIBIT B-2
<Page>

            EXHIBIT C-1 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
                        CONSTRUCTION DISBURSEMENT REQUEST

                                     [Date]

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

          Re:  Construction Disbursement Request No. __________ under
               Cash Collateral and Disbursement Agreement
               Construction Disbursement Request of $_____
               Requested Disbursement Date: _________, 20__

Ladies and Gentlemen:

     Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance Biloxi
Corp. ("PFC", and jointly and severally with Premier, the "ISSUER"), hereby
submit this Construction Disbursement Request (the "CONSTRUCTION DISBURSEMENT
REQUEST") pursuant to that certain Cash Collateral and Disbursement Agreement
dated as of January 23, 2004 (the "AGREEMENT"). Capitalized terms used herein
without definition shall have the meanings assigned in the Agreement.

     The Issuer hereby requests that you, in your capacity as Disbursement Agent
under the Agreement, on the Requested Disbursement Date set forth above:

          (i) transfer from the Construction Disbursement Account to the PFC
     Payment Account $[_____][INSERT AMOUNT FROM SECTION A1 TO SCHEDULE 1
     (PERMITTED LAND-BASED PROJECT COSTS) PLUS AMOUNT REQUESTED IN CLAUSE (II)
     TO FUND OR REPLENISH THE COMPANY'S DIRECT DISBURSEMENT ACCOUNT] (which
     shall be deemed to be an equity contribution to PFC);

          (ii) immediately after such funds have been transferred into the PFC
     Payment Account, transfer from the PFC Payment Account [$______] to the
     Bond Trustee's Construction Disbursement Account and $[________] to the
     Company's Direct Disbursement Account;

          (iii) distribute checks drawn on (or wire transfers from) the
     Construction Disbursement Account to the parties identified in SECTIONS B1
     and B2 to SCHEDULE 1 (Other Project Costs) in the amounts listed for such
     parties under SECTION B1 and B2 to SCHEDULE 1 (Other Project Costs) under
     the column "Current Payment Amount"; and

                                   Page 1 of 6
                                   EXHIBIT C-1
<Page>

          (iv) transfer $[_____] from the Construction Disbursement Account to
     the Issuer's Payment Account.

     In connection with the requested disbursements, the Issuer hereby
represents, warrants and certifies as of the date hereof as follows:

     (a)  This paragraph concerns Hard Costs. SCHEDULE 1 and the Bond
Requisition accurately lists each party for whom payment is requested and, for
each line item and for each party to whom payment is requested with respect to
such line item, the following: (i) the name of the payee to be paid; (ii) the
current payment requested with respect to the Facility; (iii) the increase or
decrease in accrued but unpaid Retainage Amount, if any, for such payee since
the last Construction Disbursement Request (after giving effect to the payment
contemplated by the Construction Disbursement Request); (iv) the total amount
contemplated to be payable to such payee under the terms of its applicable
Construction Contract through completion of all work and delivery of all
materials contemplated by the Construction Contract (i.e., the total contract
amount) with respect to the Facility; (v) the total payments made to such payee
under its applicable Construction Contract with respect to the Facility as of
the Issuance Date; (vi) the total payments made to such payee since the Issuance
Date (after giving effect to the payment contemplated by this Construction
Disbursement Request) with respect to the Facility; (vii) the sum of all
payments made to such payee (after giving effect to the payment contemplated by
this Construction Disbursement Request) (i.e., the sum of (v) and (vi) above)
with respect to the Facility; (viii) the aggregate accrued Retainage Amounts
which shall continue to be owed with respect to such Construction Contract
(after giving effect to the payment contemplated by the Construction
Disbursement Request); and (ix) the Issuer's reasonable belief as to the
percentage of the work actually completed, or the materials actually delivered,
under the Construction Contract through the date for which payment is made
hereunder (expressed as a percentage of the total work and materials
contemplated by the Construction Contract through completion), or, if payment is
to be made based on invoice, or is otherwise required by such Construction
Contract, confirmation that a copy of the applicable invoice is attached, and a
description of the purpose of such payment, specifying the line item relating to
each such payment. In the event that any Advance Construction Disbursements have
been made and have not otherwise been documented as required hereunder and under
the Agreement, SCHEDULE 1 and SCHEDULE 1 to the Bond Requisition also includes
each party to whom payment was made from such Advance Construction Disbursement
and a description of the purpose of such payments specifying the line item
relating to each such payment. The information set forth in SCHEDULE 1 and
SCHEDULE 1 to the Bond Requisition is true, correct and complete in all material
respects.

     (b)  This paragraph concerns Soft Costs. SCHEDULE 1 accurately lists each
party and/or purpose for which payment is requested and, for each line item and
for each party and/or purpose for which payment is requested with respect to
such line item, the following: (i) the name of the payee to be paid, and, (ii)
the current payment requested, and (iii) a description of the purpose of such
payment, specifying the line item relating to each such payment. In the event
that any Advance Construction Disbursements have been made and have not
otherwise been documented as required hereunder and under the Agreement,
SCHEDULE 1 also includes each party to whom

                                   Page 2 of 6
                                   EXHIBIT C-1
<Page>

payment was made from such Advance Construction Disbursement and a description
of the purpose of such payments specifying the line item relating to each such
payment. The information set forth in SCHEDULE 1 is true, correct and complete
in all material respects.

     (c)  This paragraph concerns Hard Costs. The Issuer has delivered or caused
to be delivered to the Independent Construction Consultant (a) true and complete
invoices that have been tendered for all Hard Costs pursuant to any Construction
Disbursement Request or Bond Requisition and (b) duly executed lien releases,
waivers and agreements in the form specified by EXHIBITS M-1, M-2 and M-3 and
otherwise in form and substance reasonably satisfactory to the Independent
Construction Consultant (copies of which are attached hereto as ATTACHMENT 1),
from Premier and each Contractor identified on the Construction Disbursement
Request or Bond Requisition for payment of Hard Costs acknowledging that such
Contractor has been paid in full any and all amounts due for work or services
performed and materials furnished to date in connection with the construction of
the Facility, except for (i) Retainage Amounts specified in the applicable
Construction Contract in effect as of the Issuance Date; (ii) Retainage Amounts
specified in any Construction Contract entered into after the Issuance Date
which the Independent Construction Consultant determines to be reasonably
withheld; (iii) amounts identified to be paid to such Contractor in the current
Construction Disbursement Request or Bond Requisition; (iv) Disputed Amounts
(provided that aggregate amount of Disputed Amounts identified by all
Contractors in such lien releases, affidavits and agreements, together with the
aggregate amount payable with respect to Disputed Amounts under all Construction
Contracts for which the Issuer has not delivered a lien release, affidavit and
agreement from the relevant Contractor, does not exceed the Available Advance
Construction Disbursement Amounts, PROVIDED, HOWEVER, that lien releases,
waivers and agreements need not be delivered under this clause (b) from any
single Contractor with a contract price (or expected aggregate amount to be paid
in the case of "cost plus" contracts) of less than $100,000). The lien release
summary chart attached hereto as SCHEDULE 2 and the lien releases, affidavits
and agreements attached hereto as ATTACHMENT 1 are true, correct and complete in
all material respects.

     (d)  To the Issuer's Knowledge, the construction performed as of the date
hereof is of first-class quality and substantially in accordance with the Final
Plans for the Facility and the disbursement is appropriate in light of the
percentage of construction completed and the amount of Unincorporated Materials.

     (e)  With respect to amounts requested on SCHEDULE 1 for Pre-Opening
Expenses, all such Pre-Opening Expenses have been or will be incurred and are or
will be payable in accordance with the Agreement and all of the conditions set
forth in the Agreement to the disbursement and payment of said amounts have been
satisfied.

     (f)  All the commitments, policies and endorsements required to be
delivered on or before the date of this certificate under this Agreement have
been received and are attached hereto as ATTACHMENT 2. ATTACHMENT 2 is true,
correct and complete in all material respects.

                                   Page 3 of 6
                                   EXHIBIT C-1
<Page>

     (g)  The Project Budget presently in effect is dated [__________] [choose
one of the following] [and has not been amended] [and includes all amendments
through Project Budget Amendment No. ___.] Said Project Budget accurately sets
forth the anticipated Construction Expenses through completion of construction
of the Facility in the aggregate and for each line item. Further, to the extent
the work or payment required in connection with any line item has not yet been
completed, the Issuer reasonably believes that the estimated cost to complete
such work or payment will not exceed the difference between (a) the Remaining
Budgeted Amount for such line item on the Project Budget and (b) the sum of (i)
the total payments theretofore disbursed from the Construction Disbursement
Account with respect to such line item; (ii) any Retainage Amounts then held
with respect to such line item; and (iii) the portion of the proceeds of the
FF&E Financing that the Issuer has expended in connection with such line item.

     (h)  The Project Budget continues to accurately set forth all anticipated
Pre-Opening Expenses through the Initial Operating Date in all material
respects.

     (i)  After giving effect to the requested disbursements from the
Construction Disbursement Account, there are sufficient Available Construction
Funds to pay for the anticipated costs described in Paragraphs (g) and (h) above
and any other material expenses the Issuer reasonably believes will need to be
incurred by the Issuer in order to cause the Initial Operating Date to occur on
or prior to the Operating Deadline.

     (j)  As of the date hereof, no Event of Default exists, and the requested
disbursements from the Construction Disbursement Account and the payments
contemplated from the Construction Disbursement Account in connection therewith
will not constitute, result in, nor create an Event of Default.

     (k)  As of the date hereof, the Issuer has submitted to the Disbursement
Agent all Plans which, as of the date hereof, constitute Final Plans. Further,
all disbursements requested under this Construction Disbursement Request
(including any Bond Requisition attached hereto) are for the payment of
Construction Expenses incurred for (i) work consistent with the requirements of
clause (d) above or (ii) materials that have been delivered to the Site and are
incorporated into the Facility or will be incorporated within the next ninety
(90) days, or Unincorporated Materials complying with the requirements of
SECTION 4.2.2(G) of the Agreement, a true, correct and complete inventory of
which is attached hereto as SCHEDULE 3.

     (l)  The Issuer has previously delivered to Independent Construction
Consultant and the Trustee copies of all Material Construction Contracts
(together with copies of any bonds required under SECTION 4.2.2(C) of the
Agreement).

     (m)  All Agreed Permits (as listed on in EXHIBIT 9 to the Issuer's Closing
Certificate) required for the construction of the Facility and the operation of
the Facility have either been obtained by the Contractors or the Issuer and are
in full force and effect on the date hereof, or have not yet been obtained and
Issuer has no reason to believe that any Agreed Permit not obtained as of the
date hereof will not be obtained and be in full force and effect on or prior to

                                   Page 4 of 6
                                   EXHIBIT C-1
<Page>

the date on which such Agreed Permit would be required to be in full force and
effect, so as to permit the Contractor to commence work on the Facility.

     (n)  The Issuer reasonably believes that the Initial Operating Date will
occur on or prior to the Operating Deadline.

     (o)  All proceeds of all previous Disbursement Requests, except for $[____]
remaining in the Issuer's Payment Account and $[_____] in the Company's Direct
Disbursement Account, have been expended and have been applied to Construction
Expenses in accordance with the Construction Contracts and the Disbursement
Agreement and the Bond Financing Documents. All funds remaining in the Issuer's
Payment Account represent checks (or wire transfers) that have been issued by
the Issuer but have not yet cleared. SCHEDULE 4 accurately lists the
Construction Expenses paid from the Issuer's Payment Account since the last
Requested Disbursement Date, in each case, segregated by line item. The
information set forth on SCHEDULE 4 is true, correct and complete.

     (p)  The sum of (i) amount on deposit in the Company's Direct Disbursement
Account, plus (ii) the equity contribution to PFC requested in this Construction
Disbursement Request to fund or replenish the Company's Direct Disbursement
Account plus (iii) the aggregate amount outstanding with respect to checks
written (or wire transfers) that have been issued by Premier to pay Permitted
Land-Based Project Costs which have not been documented as required in the
SECTION 3.03(B)(2) of the Bond Loan Agreement and the Disbursement Agreement for
other Disbursements, does not exceed $500,000. SCHEDULE 5 accurately lists the
Permitted Land-Based Project Costs paid from the Company's Direct Disbursement
Account since the last Requested Disbursement Date, in each case, segregated by
line item. The information set forth on SCHEDULE 5 is true, correct and complete
in all material respects.

     (q)  All proceeds of all previous Bond Requisitions, except for $[_____]
remaining in the Bond Trustee's Construction Disbursement Account and $[____] in
the Company's Direct Disbursement Account, have been expended and have been
applied to Permitted Land Based Project Costs in accordance with the
Construction Contracts, the Disbursement Agreement and the Bond Financing
Documents. All funds remaining in the Bond Trustee's Construction Disbursement
Account, represent checks (or wire transfers) that have been issued on behalf of
the Issuer but have not yet cleared.

     (r)  [INCLUDE THE FOLLOWING CERTIFICATION IF THE FUNDS ARE REQUESTED TO BE
DISBURSED TO THE PFC PAYMENT ACCOUNT:] The amounts transferred to the Bond
Trustee's Construction Disbursement Account shall be used solely for the purpose
of purchasing Bonds and paying Permitted Land-Based Project Costs as identified
on the copy of the Bond Requisition attached hereto in accordance with the Bond
Financing Documents. The amounts transferred to the Company's Direct
Disbursement Account shall be used solely for the purpose of purchasing Bonds
and paying Permitted Land-Based Project Costs from time to time in accordance
with the Bond Financing Documents.

                                   Page 5 of 6
                                   EXHIBIT C-1
<Page>

     (s)  [INCLUDE THE FOLLOWING CERTIFICATION IF THE FUNDS ARE REQUESTED TO BE
DISBURSED TO THE PFC PAYMENT ACCOUNT] PFC hereby confirms that the conditions
precedent set forth in SECTION 8 of the Bond Purchase Contract have been
satisfied or waived.

     (t)  [INCLUDE THE FOLLOWING CERTIFICATION IF FUNDS ARE NOT REQUESTED TO BE
DISBURSED TO THE PFC PAYMENT ACCOUNT:] No funds are requested herein to be
disbursed to the PFC Payment Account.

     (u)  This certificate is submitted concurrently with the Available
Construction Funds Certificate in the form of EXHIBIT D-1 to the Agreement, and
if applicable, a Tidelands Lease Certificate in the form of EXHIBIT C-6 to the
Agreement.

     The Disbursement Agent is entitled to rely on the foregoing
representations, warranties and certifications in authorizing and making the
disbursements requested by this Construction Disbursement Request.

     Attached to this Construction Disbursement Request as EXHIBITS 1 through 3,
as applicable, are certificates from the General Contractor, the Independent
Construction Consultant and the Architect, as applicable.

                                  PREMIER ENTERTAINMENT BILOXI LLC,
                                  on behalf of itself and Premier Finance Biloxi
                                  Corp.,
                                  as Issuer

                                  By:
                                     -------------------------------------------
                                  Name:
                                  Title:

[IF A BOND REQUISITION REQUESTING FUNDING OF PERMITTED LAND-BASED PROJECT COSTS
IS ATTACHED, PFC'S SIGNATURE SHALL ALSO BE REQUIRED:]

                                  PREMIER FINANCE BILOXI CORP.

                                  By:
                                     -------------------------------------------
                                  Name:
                                  Title:

                                   Page 6 of 6
                                   EXHIBIT C-1
<Page>

                            SCHEDULE 1 TO EXHIBIT C-1
                                   COST REPORT
                                DATE:___________

A. PERMITTED LAND-BASED PROJECT COSTS

1. CONSTRUCTION EXPENSES- HARD COSTS

Equity contribution to PFC in an amount equal to $______________ to be disbursed
to the PFC Payment Account and thereafter to the Bond Construction Fund. (1)

2. BOND TRUSTEE-CONSTRUCTION DISBURSEMENT ACCOUNT

Equity contribution to PFC in an amount equal to $______________ to be disbursed
to the PFC Payment Account and thereafter to the Company's Direct Disbursement
Account. (2)

B. OTHER PROJECT COSTS

1. CONSTRUCTION EXPENSES - HARD COSTS

<Table>
<Caption>
                             (iii) Increase/                                                                        (viii)
                             Decrease in                                        (vi)                                Aggregate
                             Retainage       (iv)            (v)                Payments Under                      Accrued and
                             Amount Since    Total Amount    Payments Under     Construction                        Unpaid Retainage
            (ii)             Last            Payable Under   Construction       Contract From   (vii)               Amounts for
(i)         Current Payment  Disbursement    Construction    Contract Prior to  and After       Total Payments      Construction
Payee       Amount           Request         Contract Terms  Issuance Date      Issuance Date   to Date [(v)+ (vi)] Contract
------------------------------------------------------------------------------------------------------------------------------------
<S>         <C>              <C>             <C>             <C>                <C>             <C>                 <C>
Line Item:

<Caption>
(i)         (ix)             (x)
Payee       % of             Amount Earned
            Construction     to Date
            Contract Work    [(vii)+
            Completed        (viii)]
------------------------------------------
<S>         <C>              <C>
Line Item:
</Table>

                            SCHEDULE 1 TO EXHIBIT C-1
                                   COST REPORT

----------
(1) The equity contribution for Hard Costs listed in Item A1 shall equal: (i)
the amount of Permitted Land-Based Project Costs requested to be paid under the
Bond Requisition attached hereto as Exhibit 4.

(2) The equity contribution listed in Item A2 shall equal the amount requested
to fund or replenish the Company's Direct Disbursement Account, which amount
shall not exceed the Available Direct Payment Amount.

                                   Page 1 of 3
                            SCHEDULE 1 TO EXHIBIT C-1
<Page>

TOTAL FOR LINE
ITEM

Line Item:

TOTAL FOR LINE
ITEM

2.  CONSTRUCTION EXPENSES- SOFT COSTS

<Table>
<Caption>
(i)                (ii)
Payee              Current Payment Amount      (iii) Description of Purpose of Soft Cost Construction Expense
<S>                <C>                         <C>
Line Item:

TOTAL FOR LINE
ITEM

Line Item:

TOTAL FOR LINE
ITEM
</Table>

                                   Page 2 of 3
                            SCHEDULE 1 TO EXHIBIT C-1
<Page>

                            SCHEDULE 1 TO EXHIBIT C-1
                                   COST REPORT
                                DATE: ___________

PRE-OPENING EXPENSES

<Table>
<Caption>
(i)                  (ii)
Payee                Current Payment Amount
<S>                  <C>
Line Item:

TOTAL FOR
LINE ITEM

Line Item:

TOTAL FOR
LINE ITEM
</Table>

                                   Page 3 of 3
                            SCHEDULE 1 TO EXHIBIT C-1
<Page>

                            SCHEDULE 2 TO EXHIBIT C-1
                      LIEN RELEASE SUMMARY - MASTER LIST(1)
          Waivers received for work billed through __________ __, ____
        Submitted pursuant to Section4.2.2 of the Disbursement Agreement

<Table>
<Caption>
                                     PAYMENT APPLICATION REFERENCE                          WAIVER AMOUNT
                                 --------------------------------------   ------------------------------------------------
                                          COMPANY
                                          ADVANCE        CONTRACTOR /       CONDITIONAL                      TOTAL WAIVERS
    CONTRACTOR / SUBCONTRACTOR   DATE    REQUEST #      SUBCONTRACTOR #   (CURRENT PERIOD)   UNCONDITIONAL    (CUMULATIVE)    NOTES
------------------------------------------------------------------------------------------------------------------------------------
<S>                              <C>     <C>            <C>                <C>               <C>             <C>              <C>

</Table>

----------
(1) Summary chart should address all Project Costs (including Permitted
Land-Based Project Costs).

                                   Page 1 of 1
                            SCHEDULE 2 TO EXHIBIT C-1
<Page>

                            SCHEDULE 3 TO EXHIBIT C-1
             UNINCORPORATED MATERIALS INVENTORY SUMMARY NO.___(1)

                            DATE:____________________

<Table>
<Caption>
                                                                                                    (COLUMN E)
                   ADDRESS OF LOCATION OF                                                        STORED MATERIALS
  CONTRACTOR /           OFF-SITE                                         (COLUMN D)                 (AMOUNTS
 SUBCONTRACTOR/    STORED MATERIALS (IF        DESCRIPTION OF     AMOUNT SHOWN IN COLUMN "F"      REQUESTED THIS
 SUPPLIER NAME           AVAILABLE)           STORED MATERIALS     ON PREVIOUS APPLICATION       ADVANCE REQUEST)
-------------------------------------------------------------------------------------------------------------------
<S>                <C>                        <C>                 <C>                            <C>

TOTALS

<Caption>
   (COLUMN F)            (COLUMN G)
STORED MATERIALS      TOTAL MATERIALS
WHICH WERE PUT IN     PRESENTLY STORED
PLACE THIS PERIOD         (D+E-F-G)
<S>                   <C>

</Table>

----------
(1) Summary chart should address all Project Costs (including Permitted
Land-Based Project Costs).
                                   Page 1 of 1
                           SCHEDULE 3 TO EXHIBIT C-1
<Page>

                           ATTACHMENT 1 TO EXHIBIT C-1

                                  LIEN RELEASES

                                   Page 1 of 1
                          ATTACHMENT 1 TO EXHIBIT C-1
<Page>

                           ATTACHMENT 2 TO EXHIBIT C-1

                   TITLE POLICES, COMMITMENTS AND ENDORSEMENTS

                                  Page 1 of 1
                           ATTACHMENT 2 TO EXHIBIT C-1
<Page>

                            SCHEDULE 4 TO EXHIBIT C-1
   RECONCILIATION OF CONSTRUCTION EXPENSES PAID FROM ISSUER'S PAYMENT ACCOUNT

                            DATE:____________________

--------------------------------------------------------------------------------

                                   Page 1 of 1
                            SCHEDULE 4 TO EXHIBIT C-1
<Page>

                            SCHEDULE 5 TO EXHIBIT C-1
 RECONCILIATION OF CONSTRUCTION EXPENSES PAID FROM COMPANY'S DIRECT DISBURSEMENT
                                     ACCOUNT

                            DATE:____________________

--------------------------------------------------------------------------------

                                   Page 1 of 1
                            SCHEDULE 5 TO EXHIBIT C-1
<Page>

                            EXHIBIT 1 TO EXHIBIT C-1
                       CERTIFICATE OF GENERAL CONTRACTOR

                                     [Date]

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

     Re:  Construction Disbursement Request dated ______________, 20__ of
          Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance
          Biloxi Corp. ("PFC", and jointly and severally with Premier, the
          "ISSUER")

Ladies and Gentlemen:

     Roy Anderson Corp (the "GENERAL CONTRACTOR") hereby certifies as follows:

     (a)  The General Contractor has reviewed the above referenced Construction
Disbursement Request and the Cash Collateral and Disbursement Agreement dated as
of January 23, 2004 (the "AGREEMENT"), to which the Issuer is a party, to the
extent necessary to understand the defined terms contained herein and in the
Construction Disbursement Request that are incorporated by reference from the
Agreement and to provide the certification contained herein. Capitalized terms
used herein and not otherwise defined shall have the meanings ascribed to them
in the Agreement.

     (b)  The General Contractor hereby certifies and confirms: (i) the accuracy
of each of the certifications contained in paragraphs (d) and (g) relating to
the GMP Contract (including the "Direct Purchase Items" as defined in the GMP
Contract); (ii) to the General Contractor's Knowledge, the accuracy of each of
the certifications contained in paragraphs (d) and (g) relating to any other
Construction Contract; and (iii) the accuracy of the certifications contained in
paragraph (m) (only with respect to Agreed Permits required for the construction
of the Facility required to be obtained by the General Contractor pursuant to
the GMP Contract in the above-referenced Construction Disbursement Request as
they apply to that portion of the Facility to be constructed pursuant to the GMP
Contract); provided that where any certification of the Issuer is limited to the
Issuer's Knowledge, for the purpose of this certificate such certification shall
instead be made to the General Contractor's Knowledge.

                                   Page 1 of 2
                            EXHIBIT 1 TO EXHIBIT C-1
<Page>

     (c)  The General Contractor hereby certifies and confirms that it believes
that, with respect to that portion of the Facility to be constructed pursuant to
the GMP Contract, the Initial Operating Date will occur on or prior to the
Operating Deadline.

     (d)  The General Contractor hereby acknowledges that the portion of the
Project Budget related to payment under its GMP Contract with the Issuer in
effect as of the date hereof is: (i) the Initial Project Budget as it has been
amended by all applicable Project Budget amendments; and (ii) the Project Budget
pursuant to which the Facility is currently being constructed.

     (e)  The General Contractor hereby certifies that, to the General
Contractor's Knowledge, that portion of the Facility to be constructed pursuant
to the GMP Contract will be constructed in accordance with the Project Budget so
as to contain at least the Minimum Facilities.

          The Disbursement Agent and the Issuer are entitled to rely on the
foregoing representations, warranties and certifications in authorizing and
making the disbursement requested in the Disbursement Request.

                                      ROY ANDERSON CORP

                                      By:
                                         ---------------------------------------
                                      Name:
                                      Title:

                                   Page 2 of 2
                            EXHIBIT 1 TO EXHIBIT C-1
<Page>

                            EXHIBIT 2 TO EXHIBIT C-1
               CERTIFICATE OF INDEPENDENT CONSTRUCTION CONSULTANT

                                     [Date]

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

Re:  Construction Disbursement Request dated ______________, 20__ of
     Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance Biloxi
     Corp. ("PFC", and jointly and severally with Premier, the "ISSUER")

Ladies and Gentlemen:

     Professional Associates Construction Services, Inc. (the "INDEPENDENT
CONSTRUCTION CONSULTANT") hereby certifies as follows:

     (a)  The Independent Construction Consultant has reviewed the above
referenced Construction Disbursement Request and the Cash Collateral and
Disbursement Agreement dated as of January 23, 2004 (the "AGREEMENT"), to which
the Issuer is a party, to the extent necessary to understand the defined terms
contained herein and in the Construction Disbursement Request that are
incorporated by reference from the Agreement and to provide the certification
contained herein. Capitalized terms used herein and not otherwise defined shall
have the meanings ascribed to them in the Agreement.

     (b)  The Independent Construction Consultant hereby acknowledges receipt of
the lien releases, affidavits and agreements from Premier and each Contractor as
required by clause (c) of the Issuer's Disbursement Request and SECTION 4.2.2(D)
of the Disbursement Agreement and confirms that the amounts requested to be paid
to each such person are appropriately and accurately reflected in the Issuer's
Disbursement Request (including the Project Costs identified on the Bond
Requisition attached hereto as EXHIBIT 4) and such lien releases.

     (c)  The Independent Construction Consultant hereby certifies and confirms
the accuracy of each of the certifications contained in paragraphs (a), (b),
(c), (d) (to the best of its Knowledge after due inquiry), (g) (solely as to the
second sentence of clause (g), to the best of its

                                   Page 1 of 3
                            EXHIBIT 2 TO EXHIBIT C-1
<Page>

Knowledge after due inquiry), (i), (k) (to the best of its Knowledge), and (l)
of the above-referenced Construction Disbursement Request; provided that where
any certification of the Issuer is limited to the Issuer's Knowledge, for the
purpose of this certificate such certification shall instead be made to the
Independent Construction Consultant's Knowledge.

     (d)  The Independent Construction Consultant hereby certifies and confirms
that it believes that the Initial Operating Date will occur on or prior to the
Operating Deadline.

          The Disbursement Agent and the Issuer are entitled to rely on the
foregoing representations, warranties and certifications in authorizing and
making the disbursement requested in the Disbursement Request.

                                      PROFESSIONAL ASSOCIATES
                                      CONSTRUCTION SERVICES, INC.

                                      By:
                                         ---------------------------------------
                                      Name:
                                      Title:

                                   Page 2 of 2
                            EXHIBIT 2 TO EXHIBIT C-1
<Page>

                            EXHIBIT 3 TO EXHIBIT C-1
                            CERTIFICATE OF ARCHITECT

                                     [Date]

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

Re:  Construction Disbursement Request dated __________, 20__ of
     Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance Biloxi
     Corp. ("PFC", and jointly and severally with Premier, the "ISSUER")

Ladies and Gentlemen:

     Paul Steelman, Ltd. (the "ARCHITECT") hereby certifies as follows:

     (a)  The Architect has reviewed the above referenced Construction
Disbursement Request and the Cash Collateral and Disbursement Agreement dated as
of January 23, 2004 (the "AGREEMENT"), to which the Issuer is a party, to the
extent necessary to understand the defined terms contained herein and in the
Construction Disbursement Request that are incorporated by reference from the
Agreement and to provide the certification contained herein. Capitalized terms
used herein and not otherwise defined shall have the meanings ascribed to them
in the Agreement.

     (b)  The Architect hereby certifies and confirms with respect to that
portion of the Facility constructed pursuant to the Plans prepared by the
Architect the accuracy of the certifications in Paragraphs (d), (g) and (m) of
the above-referenced Construction Disbursement Request.

     (c)  The Architect hereby certifies and confirms that it believes that the
Initial Operating Date will occur on or prior to the Operating Deadline.

          The Disbursement Agent and the Issuer are entitled to rely on the
foregoing representations, warranties and certifications in authorizing and
making the disbursement requested in the Disbursement Request.

                                   Page 1 of 2
                            EXHIBIT 3 TO EXHIBIT C-1
<Page>

                                      PAUL STEELMAN, LTD.

                                      By:
                                         ---------------------------------------
                                      Name:
                                      Title:

                                   Page 2 of 2
                            EXHIBIT 3 TO EXHIBIT C-1
<Page>

                            EXHIBIT 4 TO EXHIBIT C-1

                                BOND REQUISITION

                       [ISSUER TO ATTACH COPY OF COMPLETED
                        BOND REQUISITION, IF APPLICABLE]

                                   Page 1 of 1
                            EXHIBIT 4 TO EXHIBIT C-1
<Page>

            EXHIBIT C-2 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
                        PRE-OPENING DISBURSEMENT REQUEST

                                     [Date]

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

     Re:  Pre-Opening Disbursement Request No. ___________ under
          Cash Collateral and Disbursement Agreement
          Pre-Opening Disbursement Request of $_____
          Requested Disbursement Date:_____________, 20___

Ladies and Gentlemen:

     Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance Biloxi
Corp. ("PFC", and jointly and severally with Premier, the "ISSUER") hereby
submits this Pre-Opening Disbursement Request (the "PRE-OPENING DISBURSEMENT
REQUEST") pursuant to that certain Cash Collateral and Disbursement Agreement
dated as of January 23, 2004 (the "AGREEMENT"). Capitalized terms used herein
without definition shall have the meanings assigned in the agreement.

     The Issuer hereby requests that you, in your capacity as Disbursement Agent
under the Agreement, on the Requested Disbursement Date set forth above, (i)
distribute checks drawn on, or wire transfer from, the Construction Disbursement
Account to the parties identified on SCHEDULE 1 attached hereto and in the
respective amounts listed for such parties on SCHEDULE 1 under the column
"Current Payment Amount" and (ii) causing $[____] to be withdrawn from the
Construction Disbursement Account and deposited into the Issuer's Payment
Account.

     In connection with the requested disbursements, the Issuer hereby
represents, warrants and certifies as of the date hereof as follows:

     (a)  SCHEDULE 1 accurately lists each party and/or purpose for which
payment is requested and, for each line item and for each party and/or purpose
for which payment is requested with respect to such line item, the following:
(i) the name of the payee to be paid, and, (ii) the current payment requested,
and (iii) a description of the purpose of such payment, specifically the line
item relating to each such payment. The information set forth in SCHEDULE 1 is
true, correct and complete in all material respects.

                                   Page 1 of 3
                                   EXHIBIT C-2
<Page>

     (b)  All funds which are requested to be disbursed on SCHEDULE 1 will be
used to pay Pre-Operating Expenses that have been or will be incurred and are or
will be payable in accordance with the Agreement and the Indenture and all of
the conditions set forth in the Agreement and the Indenture to the disbursement
and payment of said amounts have been satisfied.

     (c)  The Project Budget presently in effect is dated [____________] [choose
any of the following] [and has not been amended] [and includes all amendments
through Project Budget Amendment No. __.] Said Project Budget accurately sets
forth the anticipated Construction Expenses through completion of construction
of the Facility in the aggregate and for each line item. Further, to the extent
the work or payment required in connection with any line item has not yet been
completed, the Issuer reasonably believes that the estimated cost to complete
such work or payment will not exceed the difference between (a) the Remaining
Budgeted Amount for such line item on the Project Budget and (b) the sum of (i)
the total payments theretofore disbursed from the Construction Disbursement
Account with respect to such line item; (ii) any Retainage Amounts then held
with respect to such line item; and (iii) the portion of the proceeds of the
FF&E Financing that the Issuer has expended in connection with such line item.

     (d)  The Project Budget continues to accurately set forth all anticipated
Pre-Opening Expenses through the Initial Operating Date in all material
respects.

     (e)  After giving effect to the requested disbursements from the
Construction Disbursement Account, there are sufficient Available Construction
Funds to pay for the anticipated costs described in Paragraphs (c) and (d) above
and any other expenses the Issuer reasonably believes will need to be incurred
by the Issuer in order to cause the Initial Operating Date to occur on or prior
to the Operating Deadline.

     (f)  As of the date hereof, no Event of Default exists, and the requested
disbursements from the Construction Disbursement Account and the payments
contemplated from the Construction Disbursement Account in connection therewith
will not constitute, result in, nor create an Event of Default

     (g)  All disbursements requested under this Pre-Opening Disbursement
Request are for the payment of Pre-Opening Expenses incurred for work consistent
with the preparation of the facility for opening and operation.

     (h)  The Issuer reasonably believes that the Initial Operating Date will
occur on or prior to the Operating Deadline.

     (i)  All proceeds of all previous Disbursement Requests, except for
$[______] remaining in the Issuer's Payment Account and $[____] remaining in the
Company's Direct Disbursement Account, have been expended and have been applied
to Project Costs in accordance with the Disbursement Agreement and the Bond
Financing Documents. All funds remaining in the Issuer's Payment Account
represent checks (or wire transfers) that have been

                                   Page 2 of 3
                                   EXHIBIT C-2
<Page>

issued by the Issuer but have not yet cleared or checks that will be issued in
the ordinary course of business. SCHEDULE 2 accurately lists the Project Costs
paid from the Issuer's Payment Account since the last Requested Disbursement
Date, in each case, segregated by line item. The information set forth on
SCHEDULE 2 is true, correct and complete in all material respects.

     The Disbursement Agent is entitled to rely on the foregoing
representations, warranties and certifications in authorizing and making the
disbursements requested by this Pre-Opening Disbursement Request.

                                PREMIER ENTERTAINMENT BILOXI LLC,
                                on behalf of itself and Premier Finance Biloxi
                                Corp., as Issuer

                                By:
                                   --------------------------------------------
                                Name:
                                Title:

                                By:
                                   --------------------------------------------
                                Name:
                                Title:(1)

----------
(1)  [After Initial Operating Date, this certificate must be signed by two
     officers of Premier, one of whom must be the principal executive officer,
     the principal financial officer, the treasurer or the principal accounting
     officer of Premier.]

                                   Page 3 of 3
                                   EXHIBIT C-2
<Page>

                            SCHEDULE 1 TO EXHIBIT C-2
                                   COST REPORT

                                   Page 1 of 1
                            SCHEDULE 1 TO EXHIBIT C-2
<Page>

                            SCHEDULE 2 TO EXHIBIT C-2

                         RECONCILIATION OF PROJECT COSTS
                       PAID FROM ISSUER'S PAYMENT ACCOUNT

                                   Page 1 of 1
                            SCHEDULE 2 TO EXHIBIT C-2
<Page>

            EXHIBIT C-3 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
          FORM OF ADVANCE CONSTRUCTION DISBURSEMENT REQUEST CERTIFICATE

                                     [Date]

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Copies to:

Professional Associates Construction Services
as Independent Construction Consultant
942 East Chapman Avenue
Orange, California 92866
Attention: Kent Robertson

     Re:  Advance Construction Disbursement Request No. ____________ Under
          Cash Collateral and Disbursement Agreement
          Amount Requested: $
          Requested Disbursement Date: __________, 20__

Ladies and Gentlemen:

     Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance Biloxi
Corp. ("PFC", and jointly and severally with Premier, the "ISSUER"), hereby
submits this Advance Construction Disbursement Request (the "ADVANCE
CONSTRUCTION DISBURSEMENT REQUEST") pursuant to that certain Cash Collateral and
Disbursement Agreement dated as of January 23, 2004 (the "AGREEMENT").
Capitalized terms used herein without definition shall have the meanings
assigned in the Agreement.

     The Issuer hereby requests you, in your capacity as Disbursement Agent
under the Agreement, on the Requested Disbursement Date:

          (i)   transfer $_______ from the Construction Disbursement Account to
     the PFC Payment Account (which shall be deemed to be an equity contribution
     to PFC);

          (ii)  immediately after such funds have been transferred into the PFC
     Payment Account, transfer such funds from the PFC Payment Account to the
     Company's Direct Disbursement Account;

                                   Page 1 of 3
                                   EXHIBIT C-3
<Page>

          (iii) transfer $_______ from the Construction Disbursement Account to
     the Issuer's Payment Account.

     In connection with the requested disbursements, the Issuer hereby
represents, warrants and certifies as of the date hereof as follows:

     (a)  amounts disbursed pursuant to this Advance Construction Disbursement
Request shall be used solely for the following purposes, which purposes are not
prohibited by the Indenture: _______;

     (b)  as of the date hereof, no Event of Default exists, and the requested
disbursement from the Construction Disbursement Account will not constitute,
result in, nor create an Event of Default;

     (c)  the Available Advance Construction Disbursement Amount MINUS the
amount of the currently requested Advance Construction Disbursement shall be
greater than zero;

     (d)  the Project Budget presently in effect is dated [________][CHOOSE
ONE][and has not been amended] [and includes all amendments through Project
Budget Amendment No._______]. Said Project Budget accurately sets forth the
anticipated Construction Expenses through completion of construction of the
Facility in the aggregate and for each line item. Further, to the extent the
work or payment required in connection with any line item has not yet been
completed, the Issuer reasonably believes that the estimated cost to complete
such work or payment will not exceed the difference between (a) the Remaining
Budgeted Amount for such line item on the Project Budget less (b) the sum of (i)
the total payments theretofore disbursed from the Construction Disbursement
Account with respect to such line item (ii) any Retainage Amounts then held with
respect to such line item and (iii) the portion of the proceeds of the FF&E
Financing that the Issuer has expended in connection with such line item.

     (e)  the Project Budget continues to accurately set forth all anticipated
Pre-Opening Expenses through the Initial Operating Date in all material
respects;

     (f)  after giving effect to the requested disbursements from the
Construction Disbursement Account, there are sufficient Available Construction
Funds to pay for the anticipated costs described in Paragraphs (d) and (e) above
and any other expenses the Issuer reasonably believes will need to be incurred
by the Issuer in order to cause the Initial Operating Date to occur on or prior
to the Operating Deadline.

     (g)  [INCLUDE THE FOLLOWING CERTIFICATION IF THE FUNDS TO BE DISBURSED TO
THE PFC PAYMENT ACCOUNT:] The sum of (i) amount on deposit in the Company's
Direct Disbursement Account, plus (ii) the equity contribution to PFC requested
in this Advance Construction Disbursement Request to fund or replenish the
Company's Direct Disbursement Account plus (iii) the aggregate amount
outstanding with respect to checks written (or wire transfers) that have

                                   Page 2 of 3
                                   EXHIBIT C-3
<Page>

been issued by Premier to pay Permitted Land-Based Project Costs which have not
been documented as required in SECTION 3.03(b)(2) of the Bond Loan Agreement and
the Disbursement Agreement for other Disbursements, does not exceed $500,000.
The amounts transferred to the Company's Direct Disbursement Account shall be
used solely for the purpose of purchasing Bonds and paying for Permitted
Land-Based Project Costs from time to time in accordance with the Bond Financing
Documents.

     (h)  [INCLUDE THE FOLLOWING CERTIFICATION IF THE FUNDS TO BE DISBURSED TO
THE PFC PAYMENT ACCOUNT:] The conditions precedent set forth in SECTION 8 of the
Bond Purchase Contract have been satisfied or waived.

     (i)  [INCLUDE THE FOLLOWING CERTIFICATION IF FUNDS ARE NOT REQUESTED TO BE
DISBURSED TO THE PFC PAYMENT ACCOUNT:] No funds are requested herein to be
disbursed to the PFC Payment Account.

     The Disbursement Agent is entitled to rely on the foregoing
representations, warranties and certifications in authorizing and making the
disbursements requested by this Advance Construction Disbursement Request.
Attached to this Advance Construction Disbursement Request as EXHIBIT 1 is a
certificate from the Independent Construction Consultant.

                                PREMIER ENTERTAINMENT BILOXI LLC,
                                on behalf of itself and Premier Finance Biloxi
                                Corp., as Issuer(1)

                                By:
                                   ---------------------------------------------
                                Name:
                                Title:

                                By:
                                   ---------------------------------------------
                                Name:
                                Title:

[IF A BOND REQUISITION REQUESTING FUNDING OF PERMITTED LAND-BASED PROJECT COSTS
IS ATTACHED, PFC'S SIGNATURE SHALL ALSO BE REQUIRED:]

                                PREMIER FINANCE BILOXI CORP.

----------
(1)  [After Initial Operating Date, this certificate must be signed by two
     officers of Premier, one of whom must be the principal executive officer,
     the principal financial officer, the treasurer or the principal accounting
     officer of Premier.]

                                   Page 3 of 3
                                   EXHIBIT C-3
<Page>

                                By:
                                   ---------------------------------------------
                                Name:
                                Title:

                                   Page 4 of 3
                                   EXHIBIT C-3
<Page>

                            EXHIBIT 1 TO EXHIBIT C-3
               CERTIFICATE OF INDEPENDENT CONSTRUCTION CONSULTANT

                                     [Date]

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

Re:  Advance Construction Disbursement Request dated ______________, 20__ of
     Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance Biloxi
     Corp. ("PFC", and jointly and severally with Premier, the "ISSUER")

Ladies and Gentlemen:

     Professional Associates Construction Services, Inc. (the "INDEPENDENT
CONSTRUCTION CONSULTANT") hereby certifies as follows:

     (a)  The Independent Construction Consultant has reviewed the above
referenced Advance Construction Disbursement Request and the Cash Collateral and
Disbursement Agreement dated as of January 23, 2004 (the "AGREEMENT"), to which
the Issuer is a party, to the extent necessary to understand the defined terms
contained herein and in the Advance Construction Disbursement Request that are
incorporated by reference from the Agreement and to provide the certification
contained herein. Capitalized terms used herein and not otherwise defined shall
have the meanings ascribed to them in the Agreement.

     (b)  The Independent Construction Consultant hereby confirms that the
Available Advance Construction Disbursement Amount MINUS the amount of the
currently requested Advance Construction Disbursement shall be greater than
zero.

     The Disbursement Agent and the Issuer are entitled to rely on the foregoing
representations, warranties and certifications in authorizing and making the
disbursement requested in the Disbursement Request.

                                   Page 1 of 3
                            EXHIBIT 1 TO EXHIBIT C-3
<Page>

                                        PROFESSIONAL ASSOCIATES
                                        CONSTRUCTION SERVICES, INC.

                                        By:
                                           -------------------------------------
                                        Name:
                                        Title:

                                   Page 2 of 2
                            EXHIBIT 1 TO EXHIBIT C-3
<Page>

            EXHIBIT C-4 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
            FORM OF INTEREST RESERVE ACCOUNT DISBURSEMENT CERTIFICATE

                                     [Date]

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

     Re:  Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance
          Biloxi Corp. ("PFC", and jointly and severally with Premier, the
          "ISSUER") Interest Reserve Account Disbursement

Ladies and Gentlemen:

     This certificate is delivered pursuant to SECTION 4.4(A) of that certain
Cash Collateral and Disbursement Agreement dated as of January 23, 2004 (the
"AGREEMENT"), to which you are a party. Capitalized terms used in this
certificate that are otherwise not defined shall have the meaning assigned in
the Agreement. The Issuer hereby represents, warrants and certifies as follows:

     The next Interest Payment Date with respect to the First Mortgage Notes is
__________________. The amount of interest to be paid with respect to the First
Mortgage Notes on such Interest Payment Date is $_____.

     The calculation of such amount is as follows: _____

     On _____________ [INSERT INTEREST PAYMENT DATE], the Disbursement Agent is
hereby instructed to transfer $__________ [insert amount of interest] from the
Interest Reserve Account to the Trustee for the benefit of the Noteholders to
pay interest with respect to the First Mortgage Notes under the Indenture.

                                   Page 1 of 2
                                   EXHIBIT C-4
<Page>

     The Disbursement Agent is entitled to rely on the foregoing
representations, warranties and certifications in authorizing and making the
disbursement requested in the Disbursement Request.

                                  PREMIER ENTERTAINMENT BILOXI LLC,
                                  on behalf of itself and Premier Finance Biloxi
                                  Corp., as Issuer(1)

                                  By:
                                     -------------------------------------------
                                  Name:
                                  Title:

                                  By:
                                     -------------------------------------------
                                  Name:
                                  Title:

----------
(1)  [After Initial Operating Date, this certificate must be signed by two
     officers of Premier, one of whom must be the principal executive officer,
     the principal financial officer, the treasurer or the principal accounting
     officer of Premier.]

                                   Page 2 of 2
                                   EXHIBIT C-4
<Page>

            EXHIBIT C-5 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
              FORM OF INTEREST RESERVE EXCESS TRANSFER CERTIFICATE

                                     [Date]

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

     Re:  Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance
          Biloxi Corp. ("PFC", and jointly and severally with Premier, the
          "ISSUER") Interest Reserve Account Disbursement

Ladies and Gentlemen:

     This certificate is delivered pursuant to SECTION 4.4(B) of that certain
Cash Collateral and Disbursement Agreement dated as of January 23, 2004 (the
"AGREEMENT"), to which you are a party. Capitalized terms used in this
certificate that are otherwise not defined shall have the meaning assigned in
the Agreement. The Issuer hereby represents, warrants and certifies as follows:

          1.   $______________ of the Proceeds has been deposited into the
     Interest Reserve Account.

          2.   The Issuer has caused the funds held in the Interest Reserve
     Account to be invested in accordance with SECTION 2.8 of the Agreement.

          3.   The Initial Interest Reserve Account Target as of the date hereof
     is $________________.

          4.   The amount described in clause 1 (above) exceeds the amount
     described in clause 3 (above) by $_______________ (the "INTEREST RESERVE
     EXCESS").

     The Disbursement Agent is entitled to rely on the foregoing
representations, warranties and certifications in authorizing and making the
disbursement requested below.

     The Issuer hereby irrevocably instructs the Disbursement Agent to transfer
the Interest Reserve Excess to the Construction Disbursement Account.

                                   Page 1 of 2
                                   EXHIBIT C-5
<Page>

     [IF APPLICABLE:] Premier has attached hereto as EXHIBIT 1 a Project Budget
Amendment Certificate submitted in accordance with SECTION 5.1 of the Agreement
documenting any corresponding adjustment to the [________] line item as a result
of the Initial Interest Reserve Target and transfer of the Interest Reserve
Excess to the Construction Disbursement Account.

                                  PREMIER ENTERTAINMENT BILOXI LLC,
                                  on behalf of itself and Premier Finance Biloxi
                                  Corp., as Issuer(1)

                                  By:
                                     -------------------------------------------
                                  Name:
                                  Title:

                                  By:
                                     -------------------------------------------
                                  Name:
                                  Title:

----------
(1)  [After Initial Operating Date, this certificate must be signed by two
     officers of Premier, one of whom must be the principal executive officer,
     the principal financial officer, the treasurer or the principal accounting
     officer of Premier.]

                                   Page 2 of 2
                                   EXHIBIT C-5
<Page>

            EXHIBIT C-6 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
                       FORM OF TIDELANDS LEASE CERTIFICATE

                                     [Date]

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

     Re:  Premier Entertainment Biloxi LLC ("PREMIER") Tidelands Lease Account.

Ladies and Gentlemen:

     This certificate is delivered pursuant to SECTION 6.1(a) of that certain
Cash Collateral and Disbursement Agreement dated as of January 23, 2004 (the
"AGREEMENT"), to which you are a party. Capitalized terms used in this
certificate that are otherwise not defined shall have the meaning assigned in
the Agreement. Premier hereby represents, warrants and certifies as follows:

          1.   The amount of the Tidelands Lease Required Payment Amount as of
     the date hereof is $______________.

          2.   The excess of the Tidelands Lease Required Payment Amount over
     the balance on deposit in the Tidelands Lease Account as of the date hereof
     is $_______________ (the "TIDELANDS LEASE SHORTAGE AMOUNT").

     Premier has delivered this certificate together with [INCLUDE ONE OR BOTH
OF THE FOLLOWING; HOWEVER, THE SUM OF THE AMOUNT SET FORTH IN CLAUSE (I) PLUS
THE AMOUNT SET FORTH IN CLAUSE (II) MUST EQUAL THE TIDELANDS LEASE SHORTAGE
AMOUNT]:

     (i) a check or wire transfer in an amount equal to $[______________];

     (ii) a Project Budget Amendment Certificate attached hereto as EXHIBIT 1
and submitted in accordance with SECTION 5.1 of the Agreement applying (A)
$[______] from Realized Savings and (B) $[__________] from the "contingency"
line item to fund such Tidelands Lease Shortage Amount and instructing the
Disbursement Agent to transfer $[_________][INSERT TOTAL OF CLAUSE (a) PLUS
CLAUSE (b)] from the Construction Disbursement Account into the Tidelands Lease
Account.

                                   Page 1 of 2
                                   EXHIBIT C-6
<Page>

     Premier hereby irrevocably instructs the Disbursement Agent to deposit such
funds into the Tidelands Lease Account.

                                  PREMIER ENTERTAINMENT BILOXI LLC,
                                  on behalf of itself and Premier Finance Biloxi
                                  Corp., as Issuer(1)

                                  By:
                                     -------------------------------------------
                                  Name:
                                  Title:

                                  By:
                                     -------------------------------------------
                                  Name:
                                  Title:

----------
(1)  After Initial Operating Date, this certificate must be signed by two
     officers of Premier, one of whom must be the principal executive officer,
     the principal financial officer, the treasurer or the principal accounting
     officer of Premier.

                                   Page 2 of 2
                                   EXHIBIT C-6
<Page>

            EXHIBIT D-1 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
                FORM OF AVAILABLE CONSTRUCTION FUNDS CERTIFICATE

                                     [Date]

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Professional Associates Construction Services, Inc.
as Independent Construction Consultant
942 East Chapman Avenue
Orange, CA 92866
Attn: Kent Robertson

Re:  Available Construction Funds Certificate

Ladies and Gentlemen:

     This certificate is delivered pursuant to SECTION 5.4 of that certain Cash
Collateral and Disbursement Agreement dated as of January 23, 2004 (the
"AGREEMENT"), to which the Disbursement Agent is a party. Each of Premier
Entertainment Biloxi LLC ("PREMIER") and Premier Finance Biloxi Corp. ("PFC",
and jointly and severally with Premier, the "ISSUER") hereby represents,
warrants and certifies that:

     (a)  The Available Construction Funds Schedule, attached hereto as SCHEDULE
1, is true and correct in all material respects.

     (b)  The amount set forth in Row M of such Available Construction Funds
Schedule is the amount of Available Construction Funds as of the date of such
Available Construction Funds Schedule.

     (c)  [CHOOSE ONE:][(1):] The amount currently on deposit in the Tidelands
Lease Account is equal to or exceeds the amount of the Tidelands Lease Required
Payment.][OR][(2):] The amount currently on deposit in the Tidelands Lease
Account is less than the amount of the

                                   Page 1 of 2
                                   EXHIBIT D-1
<Page>

Tidelands Lease Required Payment. Attached hereto as ATTACHMENT 1 is a Tidelands
Lease Certificate submitted in accordance with SECTION 6.1(c) of the Agreement.]

     The Disbursement Agent, the Trustee and the Independent Construction
Consultant are each entitled to rely on representations, warranties and
certifications. Capitalized terms used in this certificate that are otherwise
not defined shall have the meaning assigned in the Agreement.

                           PREMIER ENTERTAINMENT BILOXI LLC,
                           on behalf of itself and Premier Finance Biloxi Corp.,
                           as Issuer(1)

                           By:
                              --------------------------------------------------
                           Name:
                           Title:

                           By:
                              --------------------------------------------------
                           Name:
                           Title:

----------
(1)  [After Initial Operating Date, this certificate must be signed by two
     officers of Premier, one of whom must be the principal executive officer,
     the principal financial officer, the treasurer or the principal accounting
     officer of Premier.]

                                   Page 2 of 2
                                   EXHIBIT D-1
<Page>

                            SCHEDULE 1 TO EXHIBIT D-1
                      AVAILABLE CONSTRUCTION FUNDS SCHEDULE

                  Prepared as of: _______________________, 20__

<Table>
<S>                                                                                                                <C>
A    Additional Pre-Operating Revenue Anticipated (as noted on Project Budget) to be earned from the
     Construction Disbursement Account or the Issuer's Payment Account.                                            $______________

B    Additional Pre-Operating Revenue earned from investments in the Construction Disbursement Account or the
     Issuer's Payment Account, as of ______________, 20__ which date is no more than 30 days prior to the date
     of this Available Construction Funds Schedule.                                                                $______________

C    Additional Pre-Operating Revenue anticipated to be earned, from investments in the Construction
     Disbursement Account or the Issuer's Payment Account, from the date of this Available Construction Funds
     Schedule through the date Facility anticipated to be Operating                                                $______________

D    Total Additional Pre-Operating Revenue anticipated to be earned on the Construction Disbursement Account or
     the Issuer's Payment Account (Sum of B+C).                                                                    $______________

E    Additional Pre-Operating Revenue Shortfalls/Surplus (A-D).                                                    $______________

F    The Amount of FF&E Financing that the Issuer has incurred or reasonably expects to incur, or the net
     proceeds of the Additional Notes that the Issuer has issued or expects to issue, in accordance with the
     Indenture (as adjusted pursuant to clause (y) of the definition of the Additional Pre-Opening Revenue).       $______________

G    Other Additional Pre-Operating Revenue [Attach additional pages to document that such amounts constitute
     Additional Pre-Operating Revenue]                                                                             $______________

H    Total Additional Pre-Operating Revenue (D+F+G)                                                                $______________

I    Original Allocation                                                                                           $______________

J    Additional equity, Loss Proceeds or other amounts deposited into the Construction Disbursement Account        $______________

K    Total Disbursements from the Construction Disbursement Account                                                $______________

L    The proceeds of FF&E Financing that the Issuer has expended in connection with the Facility.]                 $______________

M    Available Construction Funds (I+J - (K+L))                                                                    $______________
</Table>

                                   Page 1 of 1
                            SCHEDULE 1 TO EXHIBIT D-1
<Page>

                           ATTACHMENT 1 TO EXHIBIT D-1
                           TIDELANDS LEASE CERTIFICATE

                                   Page 1 of 1
                           ATTACHMENT 1 TO EXHIBIT D-1
<Page>

            EXHIBIT D-2 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
                    FORM OF PROJECT COST SCHEDULE CERTIFICATE

                                     [Date]

Professional Associates Construction Services
as Independent Construction Consultant
942 E. Chapman Avenue
Orange, CA 92866
Attn: Kent Robertson

Re:  Project Cost Schedule Certificate

Ladies and Gentlemen:

     This certificate is delivered pursuant to SECTION 5.5 of that certain Cash
Collateral and Disbursement Agreement dated as of January 23, 2004 (the
"AGREEMENT"), to which you are a party. Premier Entertainment Biloxi LLC
("PREMIER") and Premier Finance Biloxi Corp. ("PFC", and jointly and severally
with Premier, the "ISSUER") hereby represents, warrants and certifies that:

     (a)  The attached Project Cost Schedule, attached hereto as SCHEDULE 1, is
true and correct in all material respects.

     (b)  The Issuer reasonably believes that the total amount set forth under
the heading "Total Remaining Costs" in Part I of such Project Cost Schedule for
column (iii) is the amount of Remaining Costs as of the date of such Project
Cost Schedule.

     (c)  The amount set forth in Row M of Part II of such Project Cost Schedule
is the amount of Available Construction Funds as of the date of such Project
Cost Schedule.

                                   Page 1 of 2
                                   EXHIBIT D-2
<Page>

     The Independent Construction Consultant is entitled to rely on the
foregoing representations, warranties and certifications. Capitalized terms used
in this certificate that are otherwise not defined shall have the meaning
assigned in the Agreement.

                                  PREMIER ENTERTAINMENT BILOXI LLC,
                                  on behalf of itself and Premier Finance Biloxi
                                  Corp., as Issuer(1)

                                  By:
                                     -------------------------------------------
                                  Name:
                                  Title:

                                  By:
                                     -------------------------------------------
                                  Name:
                                  Title:

----------
(1)  [After Initial Operating Date, this certificate must be signed by two
     officers of Premier, one of whom must be the principal executive officer,
     the principal financial officer, the treasurer or the principal accounting
     officer of Premier.]

                                   Page 2 of 2
                                   EXHIBIT D-2
<Page>

                            SCHEDULE 1 TO EXHIBIT D-2
                        PROJECT COST SCHEDULE CERTIFICATE

               Prepared as of: ____________________________, 20__

I.   PROJECT COSTS

                       CONSTRUCTION EXPENSES - HARD COSTS

<Table>
<Caption>
                                                                           (iii)
                                                                           Total estimated
                                                                           additional amounts to
                                                                           be paid after the date
                                                                           of this Schedule to
                                                                           complete the tasks
                         (i)                      (ii)                     included in such Line
                         Hard Costs paid from     Accrued and unpaid       Item through the date                        (v)
                         the Issuance Date to     Retainage Amounts from   the Issuer reasonably    (iv)                Expected
                         the date of this         the Issuance Date to     estimates the Initial    Remaining Budgeted  Line Item
Line Item from Project   Schedule with respect    the date of this         Operating Date will      Amount from the     Surplus or
Budget                   to such line item        Schedule                 occur                    Project Budget      Cost Overrun
<S>                      <C>                      <C>                      <C>                      <C>                 <C>

</Table>

                       CONSTRUCTION EXPENSES - SOFT COSTS

<Table>
<Caption>
                                                                           (iii)
                                                                           Total estimated
                                                                           additional amounts to
                                                                           be paid after the date
                                                                           of this Schedule to
                                                                           complete the tasks
                         (i)                      (ii)                     included in such Line
                         Soft Costs paid from     Accrued and unpaid       Item through the date                        (v)
                         the Issuance Date to     Retainage Amounts from   the Issuer reasonably    (iv)                Expected
                         the date of this         the Issuance Date to     estimates the Initial    Remaining Budgeted  Line Item
Line Item from Project   Schedule with respect    the date of this         Operating Date will      Amount from the     Surplus or
Budget                   to such line item        Schedule                 occur                    Project Budget      Cost Overrun
<S>                      <C>                      <C>                      <C>                      <C>                 <C>

</Table>

                                   Page 1 of 3
                            SCHEDULE 1 TO EXHIBIT D-2
<Page>

                              PRE-OPENING EXPENSES

<Table>
<Caption>
                                                                           (iii)
                                                                           Total estimated
                         (i)                      (ii)                     additional amounts to
                         Costs paid from the      Accrued and unpaid       be paid after the date                       (v)
                         Issuance Date to the     Retainage Amounts from   of this Schedule to      (iv)                Expected
                         date of this Schedule    the Issuance Date to     complete the tasks       Remaining Budgeted  Line Item
Line Item from Project   with respect to such     the date of this         included in such Line    Amount from the     Surplus or
Budget                   Line Item                Schedule                 Item                     Project Budget      Cost Overrun
<S>                      <C>                      <C>                      <C>                      <C>                 <C>

TOTAL REMAINING COSTS

Total
</Table>

1    (iii) [Total Estimated Additional Amounts to be Paid after the Date of this
     Schedule to complete the tasks set forth in such line item] includes
     amounts described in (ii) [Accrued and Unpaid Retainage Amount to Date]
2    (v) [Expected Line Item Surplus/ or Cost Overrun] equals (iv) [Remaining
     Budgeted Amount from the Project Budget] minus the sum of (ii) [Accrued and
     Unpaid Retainage Amount to Date] plus (iii) [Total Estimated Additional
     Amounts to be Paid after the Date of this Schedule to Complete the Tasks
     Set Forth in Such Line Item]
3    Sum of estimated Additional Amounts (Construction Expenses - Hard Costs,
     Construction Expenses - Soft Costs, and Pre-Operating Expenses) to be paid
     after the date of this Schedule

II.  ADDITIONAL PRE-OPERATING REVENUE

<Table>
<S>                                                                                                                <C>
A    Additional Pre-Operating Revenue anticipated (as noted on Project Budget) to be earned from the
     Construction Disbursement Account or the Issuer's Payment Account.                                            $______________

B    Additional Pre-Operating Revenue earned from investments in the Construction Disbursement Account or the
     Issuer's Payment Account, as of ____________ __, 20__ which date is no more than 30 days prior to the date
     of this Project Cost Schedule.                                                                                $______________

C    Additional Pre-Operating Revenue anticipated to be earned, from investments in the Construction
     Disbursement Account or the Issuer's Payment Account, from the date of this Project Cost Schedule through
     the date Facility anticipated to be Operating                                                                 $______________

D    Total Additional Pre-Operating Revenue anticipated to be earned on the Construction Disbursement Account or
     the Issuer's Payment Account (Sum of B+C).                                                                    $______________

E    Additional Pre-Operating Revenue Shortfalls/Surplus (A-D).                                                    $______________

F    The Amount of FF&E Financing that the Issuer has incurred or reasonably expects to incur, or the net
     proceeds of the Additional Notes that the                                                                     $______________
</Table>

                                   Page 2 of 3
                            SCHEDULE 1 TO EXHIBIT D-2
<Page>

<Table>
<S>                                                                                                                <C>
     Issuer has issued or expects to issue, in accordance with the Indenture (as adjusted pursuant to clause (y)
     of the definition of the Additional Pre-Opening Revenue).                                                     $______________

G    Other Additional Pre-Operating Revenue [Attach additional pages to document that such amounts constitute
     Additional Pre-Operating Revenue].                                                                            $______________

H    Total Additional Pre-Operating Revenue (D+F+G+H).                                                             $______________

I    Original Allocation.                                                                                          $______________

J    Additional equity, Loss Proceeds or other amounts deposited into the Construction Disbursement Account.       $______________

K    Total Disbursements from the Construction Disbursement Account.                                               $______________

L    The proceeds of FF&E Financing that the Issuer has expended in connection with the Facility.                  $______________

M    Available Construction Funds (H+J - (K+L)).                                                                   $______________

III. OVERALL COST OVERRUN OR SURPLUS

A.        Available Construction Funds (last item from Table II above) minus total Remaining Costs (last item
          from Table I above).                                                                                     $______________
</Table>

                                   Page 3 of 3
                            SCHEDULE 1 TO EXHIBIT D-2
<Page>

                                   EXHIBIT D-3
                         FINISHES LINE-ITEMS AND AMOUNTS
                          (from Initial Project Budget)

                                   Page 1 of 1
                                   EXHIBIT D-3
<Page>

             EXHIBIT E TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
                      PROJECT BUDGET AMENDMENT CERTIFICATE

                                     [Date]

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Copies to:

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Professional Associates Construction Services
as Independent Construction Consultant
942 East Chapman Avenue
Orange, California 92866
Attention: Kent Robertson

Re:  Amendment of Project Budget

Ladies and Gentlemen:

     The Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance Biloxi
Corp. ("PFC", and jointly and severally with Premier, the "ISSUER") requests
that the Project Budget for the Facility be amended as set forth on SCHEDULE 1
to this certificate. This certificate is delivered pursuant to SECTION 5.1.3 of
that certain Cash Collateral and Disbursement Agreement dated as of January 23,
2004 (the "AGREEMENT"), to which the Disbursement Agent is a party. In
connection with the requested Project Budget amendment, the Issuer represents,
warrants and certifies as follows:

     (a)  Such amendment is reasonably necessary in order to complete the work
          with respect to the Facility represented by such line item in the
          Project Budget that is amended.

                                   Page 1 of 3
                                    EXHIBIT E
<Page>

     (b)  Funding to pay the costs represented by any line item increase is
          available from one or more of the sources set forth in SECTION 5.1.1
          of the Agreement, as set forth on SCHEDULE 1 hereto.

     (c)  The Project Budget in effect immediately prior to the proposed
          amendment is attached to this Project Budget Amendment Certificate as
          SCHEDULE 2, and the Project Budget which will be in effect upon
          effectiveness of the proposed amendment is attached to this Project
          Budget Amendment Certificate as SCHEDULE 3.

     (d)  Immediately following any such increase: (i) the Project Budget will
          continue to provide for construction of improvements which are
          substantially consistent with or in excess of the Minimum Facilities;
          (ii) the Project Budget will permit the Initial Operating Date to
          occur on or prior to the Operating Deadline; and (iii) the Project
          Budget will reasonably establish the line item components of the work
          required to be undertaken in order to complete construction of the
          Facility, and will reasonably establish the cost of completing each
          line item component of such work.

     (e)  To the Issuer's Knowledge, the construction performed as of the date
          hereof is substantially in accordance with the Final Plans. The Issuer
          reasonably believes that the Initial Operating Date will occur on or
          prior to the Operating Deadline.

     (f)  After giving effect to the proposed amendment, the Project Budget
          accurately sets forth in all material respects the anticipated
          Construction Expenses through completion of the construction of the
          Facility, allocated among the various line item components thereof
          identified on the Project Budget in effect on the Issuance Date.

     (g)  After giving effect to the proposed amendment, the Project Budget
          accurately sets forth the anticipated Pre-Operating Expenses both in
          the aggregate and for each line item prior to the Initial Operating
          Date.

     (h)  After giving effect to the proposed amendment, there are sufficient
          Available Construction Funds to pay for the anticipated costs
          described in Paragraphs (f) and (g) above and any other expenses the
          Issuer reasonably believes will need to be incurred by the Issuer in
          order to cause the Initial Operating Date to occur on or prior to the
          Operating Deadline.

     (i)  as of the date hereof, no Event of Default exists, and the proposed
          amendment will not constitute, result in, nor create an Event of
          Default;

                                   Page 2 of 3
                                    EXHIBIT E
<Page>

     (j)  The undersigned certifies that this Project Budget Amendment
          Certificate is authorized hereby and is permitted pursuant to the
          Agreement and the Indenture and all conditions precedent thereto have
          been met; and

     (k)  SCHEDULE 1 attached hereto is true and correct in all material
          respects.

     The Disbursement Agent, the Independent Construction Consultant and the
Trustee are entitled to rely on the foregoing representations, warranties and
certifications.

     Capitalized terms used herein and not otherwise defined shall have the
meanings ascribed to them in the Agreement.

     Attached to this Project Budget Amendment Certificate as EXHIBITS 1 through
3 are certificates from the General Contractor (if the Construction Budget
Amendment affects the budgeted amounts for Hard Costs associated with any of its
work under the GMP Contract (including "Direct Purchase Items" as defined in the
GMP Contract), the Independent Construction Consultant, and the Architect (if
the Construction Budget Amendment affects that portion of the Facility
constructed pursuant to Plans prepared by it).

                              PREMIER ENTERTAINMENT BILOXI LLC,
                              on behalf of itself and Premier Finance Biloxi
                              Corp., as Issuer(1)

                              By:
                                 --------------------------------------------
                              Name:
                              Title:

                              By:
                                 --------------------------------------------
                              Name:
                              Title:

----------
(1)  [After Initial Operating Date, this certificate must be signed by two
     officers of Premier, one of whom must be the principal executive officer,
     the principal financial officer, the treasurer or the principal accounting
     officer of Premier.]

                                   Page 3 of 3
                                    EXHIBIT E
<Page>

                             SCHEDULE 1 TO EXHIBIT E

Amendment No.__ to Project Budget.

I.     INCREASES TO LINE ITEMS: [REPEAT AS
       NECESSARY]

       A.   The following line item is increased:          _____________________

            Old Amount of Line Item:                       _____________________

            Amount of Increase:                            _____________________

            New Total For Line Item:                       _____________________

            Source of Funds For Increase:                  _____________________

<Table>
<Caption>
                 Source                                        Amount
          <S>                                                  <C>
          Realized Savings                                     _______________
          Additional Pre-Operating Revenue                     _______________(1)
          Contingency                                          _______________
                 Total                                         _______________
</Table>

I.     DECREASES TO LINE ITEMS: [REPEAT AS
       NECESSARY]

       A.   The following line item is decreased:          _____________________

            Old Amount of Line Item:                       _____________________

            Amount of Decrease:                            _____________________

            New Amount of Line Item:                       _____________________

----------
(1).   Attached deposit slip for deposit of funds into the Construction
       Disbursement Account to evidence additional funds or if such increase in
       Additional Pre-Operating Revenue results from an increase in investment
       income, as described in the definition of Additional Pre-Operating
       Revenue, then a copy of the latest submitted Available Construction Funds
       Certificate shall be attached.

                                   Page 1 of 3
                             SCHEDULE 1 TO EXHIBIT E
<Page>

Reason For Decrease of Line Item (check box as appropriate):

            / / Realized Savings

            / / Reduction in "Contingency" Line Item

III.   NEW PROJECT BUDGET TOTALS

            The total Project Budget for the
            Facility is now:                                      $_____________
            The amount disbursed to date for
            the Facility is now:                                  $_____________
            Remaining amounts to be spent:                        $_____________

            Available Construction Funds for Facility:            $_____________

IV.    REALIZED SAVINGS: Either the Issuer is not decreasing line items as a
result of Realized Savings or each of the following statements is true and
correct:

       A.   Such savings are not obtained in a manner that will cause the
Facility to be inconsistent with the Minimum Facilities.

       B.   Following the subject amendment to the Project Budget,

            (i)      the total amount allocated for the line items for Finishes,
       as such line items are set forth on EXHIBIT D-3 to the Agreement, will
       not be reduced by more than 15% of the sum of the amounts allocated to
       such line items on EXHIBIT D-3 to the Agreement,

            (ii)  the "pre-opening expenses" line item on the Project Budget
       will not be evidenced by more than 15%,

            (iii) any modifications to the "contingency" lien item on the
       Project Budget are permitted under SECTION 5.1.1(c) of the Agreement, and

            (iv)  the "owner supplied FF&E", "FF&E", "working capital and
       machine loads" and the "excess liquidity" line items on the Project
       Budget will not be reduced.

       C.   Either of the following is true and correct (check the box as
appropriate) for line item ____ [REPEAT AS NECESSARY]:

       / /  1.       all work, improvements and acquisitions covered by the line
item have been completed; or

                                   Page 2 of 3
                             SCHEDULE 1 TO EXHIBIT E
<Page>

       / /  2.       all of the following have been satisfied: (a) the Issuer
has entered into Construction Contracts providing for the completion of all
tasks set forth in such line item and for all materials and services required
for such tasks for a guaranteed maximum price for each such Construction
Contract; (b) such Construction Contracts, other than the "Direct Purchase
Items" as defined in GMP Contract, provide that the portion of the Facility
covered by such line item will be completed by a specified date consistent with
the timely construction of the Facility and for a cost less than or equal to the
aggregate guaranteed maximum prices in such Construction Contracts; (c) the
aggregate guaranteed maximum prices in such Construction Contracts is equal to
or less than the revised Total Budgeted Amount for such line item and (d) if
such amendment includes Realized Savings for the "GMP Contract" line item, all
work or improvements contemplated by such line item are not subject to any
allowances under the GMP Contract and Final Plans have been completed with
respect to such work or improvements as evidenced by a Final Plans Amendment
Certificate delivered in accordance with SECTION 5.6 of the Agreement.

                                   Page 3 of 3
                             SCHEDULE 1 TO EXHIBIT E
<Page>

                             SCHEDULE 2 TO EXHIBIT E
                             EXISTING PROJECT BUDGET

                                   Page 1 of 1
                             SCHEDULE 2 TO EXHIBIT E
<Page>

                             SCHEDULE 3 TO EXHIBIT E
                               NEW PROJECT BUDGET

                                   Page 1 of 1
                             SCHEDULE 3 TO EXHIBIT E
<Page>

                             EXHIBIT 1 TO EXHIBIT E
                        CERTIFICATE OF GENERAL CONTRACTOR

                                     [Date]

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

Copies to:

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Professional Associates Construction Services
as Independent Construction Consultant
942 East Chapman Avenue
Orange, California 92866
Attn: Kent Robertson

     Re:  Project Budget Amendment Certificate dated __________, 20__ of Premier
          Entertainment Biloxi LLC ("PREMIER") and Premier Finance Biloxi Corp.
          ("PFC", and jointly and severally with Premier, the "ISSUER")

Ladies and Gentlemen:

     General Contractor hereby certifies as follows:

     (a)  The General Contractor has reviewed the above referenced Project
Budget Amendment Certificate and the Cash Collateral and Disbursement Agreement
dated as of January 23, 2004 (the "AGREEMENT"), to which the Issuer is a party,
to the extent necessary to understand the defined terms contained herein and in
the Project Budget Amendment Certificate that are incorporated by reference from
the Agreement and to provide the certification contained herein.

                                   Page 1 of 2
                             EXHIBIT 1 TO EXHIBIT E
<Page>

Capitalized terms used herein and not otherwise defined shall have the meanings
ascribed to them in the Agreement.

     (b)  The General Contractor hereby certifies and confirms the accuracy of
the certifications in Paragraphs (a), (c), (d), (e) (as to the first sentence
thereof) and (f) of the above-referenced Project Budget Amendment Certificate as
they apply to that portion of the Facility to be constructed pursuant to the GMP
Contract (including the "Direct Purchase Items" as defined in the GMP Contract);
provided that where any certification of the Issuer is limited to the Issuer's
Knowledge for the purpose of this certificate such certification shall instead
be made to the General Contractor's Knowledge.

     (c)  The General Contractor certifies and confirms that, with respect to
that portion of the Facility to be constructed pursuant to the GMP Contract, it
reasonably believes that the Initial Operating Date will occur on or prior to
the Operating Deadline.

     (d)  The undersigned has no reason to believe that the proposed amendment
is not consistent with the Final Plans and such further Plans that the
undersigned reasonably believes will become Final Plans.

     The Issuer, the Disbursement Agent, the Trustee and the Independent
Construction Consultant are entitled to rely on the foregoing representations,
warranties and certifications in authorizing and making the amendment to the
Project Budget.

                                         ROY ANDERSON CORP

                                         By:
                                            ------------------------------------
                                         Name:
                                         Title:

                                   Page 2 of 2
                             EXHIBIT 1 TO EXHIBIT E
<Page>

                             EXHIBIT 2 TO EXHIBIT E
               CERTIFICATE OF INDEPENDENT CONSTRUCTION CONSULTANT

                                     [Date]

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

Copies to:

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie
Attn: David Valpredo, Vice President

     Re:  Project Budget Amendment Certificate dated __________, 20__ of the
          Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance
          Biloxi Corp. ("PFC", and jointly and severally with Premier, the
          "ISSUER")

Ladies and Gentlemen:

     Professional Associates Construction Services, Inc. (the "INDEPENDENT
CONSTRUCTION CONSULTANT") hereby certifies as follows:

     (a)  The Independent Construction Consultant has reviewed the above
referenced Project Budget Amendment Certificate and the Cash Collateral and
Disbursement Agreement dated as of January 23, 2004 (the "AGREEMENT"), to which
the Issuer and the undersigned are a party, to the extent necessary to
understand the defined terms contained herein and in the Project Budget
Amendment Certificate that are incorporated by reference from the Agreement and
to provide the certification contained herein. Capitalized terms used herein and
not otherwise defined shall have the meanings ascribed to them in the Agreement.

     (b)  The Independent Construction Consultant hereby certifies and confirms
the accuracy of the certifications in Paragraphs (a), (c), (d) (to the best of
its Knowledge after due

                                   Page 1 of 2
                             EXHIBIT 2 TO EXHIBIT E
<Page>

inquiry), (e), (f) (to the best of its Knowledge after due inquiry) and (k) of
the above-referenced Project Budget Amendment Certificate; provided that where
any certification of the Issuer is limited to the Issuer's Knowledge for the
purpose of this certificate such certification shall instead be made to the
Independent Construction Consultant's Knowledge.

     (c)  The Independent Construction Consultant certifies and confirms that it
believes that the Initial Operating Date will occur on or prior to the Operating
Deadline.

     (d)  The Independent Construction Consultant last inspected the Facility
on _________.

     The Disbursement Agent, the Trustee and the Issuer are entitled to rely on
the foregoing representations, warranties and certifications in authorizing and
making the amendment to the Project Budget.

                                         PROFESSIONAL ASSOCIATES
                                         CONSTRUCTION SERVICES, INC.

                                         By:
                                            ------------------------------------
                                         Name:
                                         Title:

                                   Page 2 of 2
                             EXHIBIT 2 TO EXHIBIT E
<Page>

                             EXHIBIT 3 TO EXHIBIT E
                            CERTIFICATE OF ARCHITECT

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

Copies to:

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Professional Associates Construction Services
as Independent Construction Consultant
942 East Chapman Avenue
Orange, California 92866
Attn: Kent Robertson

Re:  Project Budget Amendment Certificate dated __________, 20__ of the Premier
     Entertainment Biloxi LLC ("PREMIER") and Premier Finance Biloxi Corp.
     ("PFC", and jointly and severally with Premier, the "ISSUER")

Ladies and Gentlemen:

     Paul Steelman, Ltd. (the "ARCHITECT") hereby certifies as follows:

     (a)  The Architect has reviewed the above referenced Project Budget
Amendment Certificate and the Cash Collateral and Disbursement Agreement dated
as of January 23, 2004 (the "AGREEMENT"), to which the Issuer is a party, to the
extent necessary to understand the defined terms contained herein and in the
Project Budget Amendment Certificate that are incorporated by reference from the
Agreement and to provide the certification contained herein. Capitalized terms
used herein and not otherwise defined shall have the meaning ascribed to them in
the Agreement.

                                   Page 1 of 2
                             EXHIBIT 3 TO EXHIBIT E
<Page>

     (b)  The Architect hereby certifies and confirms the accuracy of the
certifications in Paragraphs (a), (c), (d), (e), (f) and (k) of the
above-referenced Project Budget Amendment Certificate; provided that where any
certification of the Issuer is limited to the Issuer's Knowledge for the purpose
of this certificate such certification shall instead be made to the Architect's
Knowledge.

     (c)  The Architect certifies and confirms that it believes that the Initial
Operating Date will occur on or prior to the Operating Deadline.

     (d)  The Architect last inspected the Facility on _________.

     The Issuer, the Disbursement Agent, the Trustee and the Independent
Construction Consultant are entitled to rely on the foregoing representations,
warranties and certifications in authorizing and making the amendment to the
Project Budget.

                                         PAUL STEELMAN, LTD.

                                         By:
                                            ------------------------------------
                                         Name:
                                         Title:

                                   Page 2 of 2
                             EXHIBIT 3 TO EXHIBIT E
<Page>

             EXHIBIT F TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
                   CONSTRUCTION CONTRACT AMENDMENT CERTIFICATE

                                     [Date]

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Copies to:

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Professional Associates Construction Services
as Independent Construction Consultant
942 East Chapman Avenue
Orange, California 92866
Attention: Kent Robertson

Re:  Amendment No. ___ to Construction Contract dated ___________ (the
     "CONSTRUCTION CONTRACT")between __________________________ and Premier
     Entertainment Biloxi LLC ("PREMIER")

Ladies and Gentlemen:

     Premier notifies you of the amendment to the above-reference Construction
Contract as set forth on SCHEDULE 1 to this certificate. This certificate is
delivered pursuant to SECTION 5.2 of that certain Cash Collateral and
Disbursement Agreement dated as of January 23, 2004 (the "AGREEMENT"), to which
the Disbursement Agent is a party. Capitalized terms used in this certificate
that are otherwise not defined shall have the meaning assigned in the Agreement.
In connection with the Construction Contract Amendment, Premier Finance Biloxi
Corp. ("PFC", and jointly and severally with Premier, the "ISSUER") hereby
represents, warrants and certifies as follows:

     (a)  After giving effect to such Construction Contract Amendment (and any
          related amendment to the Project Budget):

                                   Page 1 of 3
                                    EXHIBIT F
<Page>

               (i)    The Project Budget will provide for construction of
          improvements which are substantially consistent with or in excess of
          the Minimum Facilities;

               (ii)   If the Construction Contract Amendment will effect a
          reduction in the scope of the work to be performed by Contractor, then
          the work eliminated from the scope of work either: (A) is not
          necessary for the completion of the Minimum Facilities, or (B) to the
          extent necessary for the completion of the Minimum Facilities or
          Finishes (as the same may be adjusted in accordance with SECTION 5.1.2
          of the Agreement), will be completed by Contractors under the new or
          amended Construction Contracts, copies of which have been provided to
          you.

               (iii)  The Facility can be completed within the line items
          pertaining to the Construction Contract: (A) in a timely manner so as
          to permit the Initial Operating Date to occur on or prior to the
          Operating Deadline; and (B) within the aggregate amounts specified for
          the line item on the Project Budget.

     (b)  After giving effect to the proposed Construction Contract Amendment
          (and any related amendment to the Project Budget), the Project Budget
          accurately sets forth in all material respects the anticipated
          Construction Expenses through completion of the construction of the
          Facility, allocated among the various line item components thereof
          identified on the Project Budget in effect on the Issuance Date.

     (c)  After giving effect to the proposed Construction Contract Amendment
          (and any related amendment to the Project Budget), the Project Budget
          accurately sets forth in all material respects all anticipated
          Pre-Opening Expenses through the Initial Operating Date.

     (d)  As of the date hereof, no Event of Default exists, and the proposed
          Construction Contract Amendment (and any related amendment to the
          Project Budget) will not constitute, result in, nor create an Event of
          Default

     The undersigned certifies that this Construction Contract Amendment
Certificate is authorized hereby and is permitted pursuant to the Agreement and
the Indenture, and all conditions precedent thereto have been met.

     The Disbursement Agent, the Independent Construction Consultant and the
Trustee are entitled to rely on the foregoing representations, warranties and
certifications.

     Attached to this Construction Contract Amendment Certificate as EXHIBITS 1
through 3 are certificates from the General Contractor (only for Hard Costs
under the GMP Contract (including "Direct Purchase Items" as defined in the GMP
Contract), unless such Hard Costs relate to an owner change directive issued by
Premier under the GMP Contract), the Independent Construction Consultant and the
Architect (for Hard Costs with respect only to Plans prepared by it).

                                   Page 2 of 3
                                    EXHIBIT F
<Page>

                                  PREMIER ENTERTAINMENT BILOXI LLC,
                                  on behalf of itself and Premier Finance Biloxi
                                  Corp., as Issuer(1)

                                  By:
                                     -------------------------------------------
                                  Name:
                                  Title:

                                  By:
                                     -------------------------------------------
                                  Name:
                                  Title:

----------
(1)  [After Initial Operating Date, this certificate must be signed by two
     officers of Premier, one of whom must be the principal executive officer,
     the principal financial officer, the treasurer or the principal accounting
     officer of Premier.]

                                   Page 3 of 3
                                    EXHIBIT F
<Page>

                             SCHEDULE 1 TO EXHIBIT F
               (COPY OF EXECUTED CONSTRUCTION CONTRACT AMENDMENT)

                                   Page 1 of 1
                             SCHEDULE 1 TO EXHIBIT F
<Page>

                            [EXHIBIT 1 TO EXHIBIT F]
                       [CERTIFICATE OF GENERAL CONTRACTOR
                   CONSTRUCTION CONTRACT AMENDMENT CERTIFICATE

                                     [Date]

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

Copies to:

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Professional Associates Construction Services
as Independent Construction Consultant
942 East Chapman Avenue
Orange, California 92866
Attn: Kent Robertson

Re:  Construction Contract Amendment Certificate dated __________, 20__ relating
     to Construction Contract dated __________ (the "CONSTRUCTION CONTRACT")
     with [Contractor] (the "CONTRACTOR")

Ladies and Gentlemen:

     Roy Anderson Corp (the "GENERAL CONTRACTOR") hereby certifies as follows:

     (a)  The General Contractor has reviewed the above-referenced Construction
Contract Amendment Certificate and the Cash Collateral and Disbursement
Agreement dated as of January 23, 2004 (the "AGREEMENT"), to which the Issuer is
a party, to the extent necessary to understand the defined terms contained
herein and in the Construction Contract Amendment Certificate that are
incorporated by reference from the Agreement, and to provide the certification
contained

                                   Page 1 of 2
                             EXHIBIT 1 TO EXHIBIT F
<Page>

herein. Capitalized terms used herein and not otherwise defined shall
have the meanings ascribed to them in the Agreement.

     (b)  The General Contractor hereby certifies and confirms: (i) the accuracy
of the certifications in Paragraphs (a) and (b) of the above-referenced
Construction Contract Amendment Certificate as they apply to the GMP Contract
(including "Direct Purchase Items" as defined in the GMP Contract); and (ii) to
the General Contractor's Knowledge, the accuracy of the certifications in
Paragraphs (a) and (b) of the above-referenced Construction Contract Amendment
Certificate as they apply to any other Construction Contracts.

     The Disbursement Agent, the Trustee and the Independent Construction
Consultant are entitled to rely on the foregoing representations, warranties and
certifications.

                                         ROY ANDERSON CORP

                                         By:
                                            ------------------------------------
                                         Name:
                                         Title:

                                   Page 2 of 2
                             EXHIBIT 1 TO EXHIBIT F
<Page>

                             EXHIBIT 2 TO EXHIBIT F
               CERTIFICATE OF INDEPENDENT CONSTRUCTION CONSULTANT
                   CONSTRUCTION CONTRACT AMENDMENT CERTIFICATE

                                     [Date]

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

Copies to:

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Re:  Construction Contract Amendment Certificate dated __________, 20__ relating
     to Construction Contract dated __________ (the "CONSTRUCTION CONTRACT")
     with __________ (the "CONTRACTOR")

Ladies and Gentlemen:

     Professional Associates Construction Services, Inc. (the "INDEPENDENT
CONSTRUCTION CONSULTANT") hereby certifies as follows:

     (a)  The Independent Construction Consultant has reviewed the
above-referenced Construction Contract Amendment Certificate and the Cash
Collateral and Disbursement Agreement dated as of January 23, 2004 (the
"AGREEMENT"), to which the Issuer is a party, to the extent necessary to
understand the defined terms contained herein and in the Construction Contract
Amendment Certificate that are incorporated by reference from the Agreement, and
to provide the certification contained herein. Capitalized terms used herein and
not otherwise defined shall have the meanings ascribed to them in the Agreement.

                                   Page 1 of 2
                             EXHIBIT 2 TO EXHIBIT F
<Page>

     (b)  The Independent Construction Consultant hereby certifies and confirms
the accuracy of the certifications in Paragraphs (a) and (b) of the
above-referenced Construction Contract Amendment Certificate.

     (c)  The Independent Construction Consultant last inspected the Facility
on _________.

     The Disbursement Agent, the Trustee and the Issuer are entitled to rely on
the foregoing representations, warranties and certifications.

                                         PROFESSIONAL ASSOCIATES
                                         CONSTRUCTION SERVICES, INC.

                                         By:
                                            ------------------------------------
                                         Name:
                                         Title:

                                   Page 2 of 2
                             EXHIBIT 2 TO EXHIBIT F
<Page>

                             EXHIBIT 3 TO EXHIBIT F
                            CERTIFICATE OF ARCHITECT
                   CONSTRUCTION CONTRACT AMENDMENT CERTIFICATE

                                     [Date]

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

Copies to:

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Professional Associates Construction Services
as Independent Construction Consultant
942 East Chapman Avenue
Orange, California 92866
Attention: Kent Robertson

Re:  Construction Contract Amendment Certificate dated __________, 20__ of
     Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance Biloxi
     Corp. ("PFC", and jointly and severally with Premier, the "ISSUER")

Ladies and Gentlemen:

     Paul Steelman, Ltd. (the "ARCHITECT") hereby certifies as follows:

     (a)  The Architect has reviewed the above-referenced Construction Contract
Amendment Certificate and the Cash Collateral and Disbursement Agreement dated
as of January 23, 2004 (the "AGREEMENT"), to which the Issuer is a party, to the
extent necessary to understand the defined terms contained herein and in the
Construction Contract Amendment Certificate that are incorporated by reference
from the Agreement, and to provide the certification contained

                                   Page 1 of 2
                             EXHIBIT 3 TO EXHIBIT F
<Page>

herein. Capitalized terms used herein and not otherwise defined shall have the
meaning ascribed to them in the Agreement.

     (b)  The Architect hereby certifies and confirms the accuracy of the
certifications in Paragraphs (a) and (b) of the above-referenced Construction
Contract Amendment Certificate.

     (c)  The Architect last inspected the Facility on _________.

     The Issuer, the Disbursement Agent, the Trustee and the Independent
Construction Consultant are entitled to rely on the foregoing representations,
warranties and certifications in authorizing the amendment to the Construction
Contract.

                                         PAUL STEELMAN, LTD.

                                         By
                                           -------------------------------------
                                         Name:
                                         Title:

                                   Page 2 of 2
                             EXHIBIT 3 TO EXHIBIT F
<Page>

            EXHIBIT G-1 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
    FORM OF ISSUER'S INITIAL OPERATING DATE DISBURSEMENT REQUEST CERTIFICATE

                                __________, 20__

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Copies to:

Roy Anderson Corp
P.O. Box 2
Gulfport, MS 39502
Attn: Roy Anderson III

Professional Associates Construction Services
as Independent Construction Consultant
942 East Chapman Avenue
Orange, California 92866
Attention: Kent Robertson

U.S. Bank National Association
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

     Re:  Cash Collateral and Disbursement Agreement
          Issuer's Initial Operating Date Disbursement Request Certificate

Ladies and Gentlemen:

     This certificate is delivered to you pursuant to SECTION 4.6.1 of that
certain Cash Collateral and Disbursement Agreement dated as of January 23, 2004
(the "AGREEMENT"), to which the Disbursement Agent is a party. Capitalized terms
used in this certificate that are otherwise not defined shall have the meanings
assigned to them in the Agreement. In connection with the requested
disbursements, the Issuer hereby represents, warrants and certifies as follows:

     (a)  The Facility is Operating and has been Operating uninterrupted for at
least 10 days prior to the date hereof.

                                   Page 1 of 2
                                   EXHIBIT G-1
<Page>

     (b)  The Permitted Amounts currently unpaid are as follows: (i) $[_______]
for the Punchlist Completion Amount; (ii) $[___] for the Disputed Amounts with
respect to the GMP Contract; (iii) $[_______] for the Disputed Amounts with
respect to the Construction Contracts other than the GMP Contract; and (iv)
$[____] for Retainage Amounts.

     (c)  All amounts required to be paid to Contractors in connection with
causing the Initial Operating Date to occur have been paid, other than Permitted
Amounts, so long as (i) 175% of the Punchlist Completion Amount for such
uncompleted Punchlist Items shall have been reserved in the Construction
Disbursement Account; (ii) 125% of the Disputed Amounts with respect to the GMP
Contract shall have been reserved in the Construction Disbursement Account;
(iii) 200% of the Disputed Amounts for any Construction Contract other than the
GMP Contract shall have been reserved in the Construction Disbursement Account;
and (iv) 100% of the Retainage Amounts shall have been reserved in the
Construction Disbursement Account (this clause (iv) collectively, with amounts
reserved under clauses (i), (ii) and (iii), the "RESERVED AMOUNT");

     (d)  The Issuer has received lien releases, affidavits and agreements from
Premier and each Contractor in the form of EXHIBIT M-1, M-2 OR M-3, as
applicable (PROVIDED, HOWEVER, lien releases, affidavits and agreements need not
be provided: (i) with respect to Permitted Amounts described in clause (c)
above; and (ii) from a single Contractor with a contract price (or expected
aggregate amount to be paid in the case of "cost plus" contracts) of less than
$100,000);

     (e)  There are no mechanic's liens or other liens, charges or orders filed
against the Facility or any portion thereof by any Contractor or any other party
that have not been discharged of record or bonded, other than Permitted Liens;
and

     (f)  Attached hereto as EXHIBIT 1 is the signed Independent Construction
Consultant's Certificate.

     The Disbursement Agent, the Trustee and the Independent Construction
Consultant are entitled to rely on the foregoing representations, warranties and
certifications in authorizing and making the disbursement requested below.

                                   Page 2 of 2
                                   EXHIBIT G-1
<Page>

     The Issuer hereby irrevocably instructs the Disbursement Agent to disburse
$[________________] from the Construction Disbursement Account (excluding the
Reserved Amount) to the following wire account: [Bank, City, State],
ABA#_______, for the account of the Issuer, Account No. __________, in
accordance with SECTION 4.6 of the Agreement.

                                  PREMIER ENTERTAINMENT BILOXI LLC,
                                  on behalf of itself and Premier Finance Biloxi
                                  Corp., as Issuer

                                  By:
                                     -------------------------------------------
                                  Name:
                                  Title:

                                  By:
                                     -------------------------------------------
                                  Name:
                                  Title:

                                   Page 3 of 2
                                   EXHIBIT G-1
<Page>

                            EXHIBIT 1 TO EXHIBIT G-1
               CERTIFICATE OF INDEPENDENT CONSTRUCTION CONSULTANT
        ISSUER'S INITIAL OPERATING DATE DISBURSEMENT REQUEST CERTIFICATE
                                     [Date]

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

Copies to:

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Re:  Issuer's Initial Operating Date Disbursement Request Certificate dated
     __________, 20__ of Premier Entertainment Biloxi LLC ("PREMIER") and
     Premier Finance Biloxi Corp. ("PFC", and jointly and severally with
     Premier, the "ISSUER")

Ladies and Gentlemen:

     Professional Associates Construction Services, Inc. (the "INDEPENDENT
CONSTRUCTION CONSULTANT") hereby certifies as follows:

     (a)  The Independent Construction Consultant has reviewed the above
referenced Issuer's Initial Operating Date Disbursement Request Certificate and
the Cash Collateral and Disbursement Agreement dated as of January 23, 2004 (the
"AGREEMENT"), to which the Issuer and the undersigned are parties to the extent
necessary to understand the defined terms contained herein and in the Issuer's
Disbursement Request Certificate that are incorporated by reference from the
Agreement, and to provide the certification contained herein. Capitalized terms
used herein and not otherwise defined shall have the meaning ascribed to them in
the Agreement.

     (b)  The Independent Construction Consultant hereby certifies and confirms
the accuracy of the certifications contained in Paragraph (a), (b) (to the best
of its Knowledge) and (c) (to the best of its Knowledge without any duty to
investigate) of the above-referenced Issuer's Initial Operating Date
Disbursement Request Certificate.

                                   Page 1 of 2
                            EXHIBIT 1 TO EXHIBIT G-1
<Page>

     (c)  The Independent Construction Consultant last inspected the Facility
on _________.

     The Disbursement Agent, the Trustee and the Issuer are entitled to rely on
the foregoing representations, warranties and certifications.

                                         PROFESSIONAL ASSOCIATES CONSTRUCTION
                                         SERVICES, INC.

                                         By:
                                            ------------------------------------
                                         Name:
                                         Title:

                                   Page 2 of 2
                            EXHIBIT 1 TO EXHIBIT G-1
<Page>

            EXHIBIT G-2 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT

                CERTIFICATE OF OBJECTION OF GENERAL CONTRACTOR TO
        ISSUER'S INITIAL OPERATING DATE DISBURSEMENT REQUEST CERTIFICATE

                                     [Date]

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

Copies to:

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Professional Associates Construction Services
as Independent Construction Consultant
942 East Chapman Avenue
Orange, California 92866
Attention: Kent Robertson

     Re:  Issuer's Initial Operating Date Disbursement Request Certificate dated
          ______________, 20__ of Premier Entertainment Biloxi LLC ("PREMIER")
          and Premier Finance Biloxi Corp. ("PFC", and jointly and severally
          with Premier, the "ISSUER")

Ladies and Gentlemen:

     Roy Anderson Corp (the "GENERAL CONTRACTOR") hereby certifies as follows:

     (a)  The General Contractor has reviewed the above referenced Issuer's
Initial Operating Date Disbursement Request Certificate and the Cash Collateral
and Disbursement Agreement dated as of January 23, 2004 (the "AGREEMENT"), to
which the Issuer is a party, to the extent necessary to understand the defined
terms contained herein and therein that are incorporated by reference from the
Agreement and to provide the certification contained herein. Capitalized

                                   Page 1 of 2
                                   EXHIBIT G-2
<Page>

terms used herein and not otherwise defined shall have the meanings ascribed to
them in the Agreement.

     (b)  The General Contractor has a reasonable basis in good faith for
disputing the Permitted Amounts described in paragraph (b) of the Issuer's
Initial Operating Date Disbursement Request Certificate, and reasonably believes
that the correct amounts for such items are as follows: (i) $[_________] for the
Punchlist Completion Amount; (ii) $[______] for the Disputed Amounts with
respect to the GMP Contract; and (iii) $[_____] for Retainage Amounts.

     The Issuer, the Disbursement Agent, the Trustee and the Independent
Construction Consultant are entitled to rely on the foregoing representations,
warranties and certifications in authorizing and making the disbursement
requested in the Issuer's Initial Operating Date Disbursement Request
Certificate.

                                         ROY ANDERSON CORP

                                         By:
                                            ------------------------------------
                                         Name:
                                         Title:

                                   Page 2 of 2
                                   EXHIBIT G-2
<Page>

            EXHIBIT G-3 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
             FORM OF ISSUER'S FINAL DISBURSEMENT REQUEST CERTIFICATE

                                __________, 20__

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

Copies to:

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Professional Associates Construction Services
as Independent Construction Consultant
942 East Chapman Avenue
Orange, California 92866
Attention: Kent Robertson

     Re:  Cash Collateral and Disbursement Agreement
          Issuer's Final Disbursement Request Certificate

Ladies and Gentlemen:

     This certificate is delivered to you pursuant to SECTION 4.7 of that
certain Cash Collateral and Disbursement Agreement dated as of January 23, 2004
(the "AGREEMENT"), to which the Disbursement Agent is a party. Capitalized terms
used in this certificate that are otherwise not defined shall have the meanings
assigned to them in the Agreement. In connection with the requested
disbursements, the Issuer hereby represents, warrants and certifies as follows:

     (a)  The Facility is Operating and has been Operating uninterrupted for at
least 10 days prior to the date hereof;

                                   Page 1 of 2
                                   EXHIBIT G-3
<Page>

     (b)  The Issuer has received final lien releases, affidavits, and
agreements from Premier and from each Contractor in the form of EXHIBIT M-4, M-5
OR M-6, as applicable copies of which are attached hereto (PROVIDED, HOWEVER,
lien releases, affidavits and agreements need not be provided from a single
Contractor with a contract price (or expected aggregate amount to be paid in the
case of "cost plus" contracts) of less than $100,000);

     (c)  There are no mechanic's liens or other liens, charges or orders filed
against the Facility or any portion thereof by any Contractor or any other party
that have not been discharged of record or bonded other than Permitted Liens;
and

     (d)  Attached hereto as EXHIBITS 1 and 2 are the signed certificates of the
Independent Construction Consultant and the General Contractor.

     The Disbursement Agent, the Trustee and the Independent Construction
Consultant are entitled to rely on the foregoing representations, warranties and
certifications in authorizing and making the disbursement requested below.

     The Issuer hereby irrevocably instructs the Disbursement Agent to disburse
all remaining sums from the Construction Disbursement Account to the following
wire account: [Bank, City, State], ABA#_______, for the account of the Issuer,
Account No. __________, in accordance with SECTION 4.7 of the Agreement.

                                  PREMIER ENTERTAINMENT BILOXI LLC,
                                  on behalf of itself and Premier Finance Biloxi
                                  Corp., as Issuer

                                  By:
                                     -------------------------------------------
                                  Name:
                                  Title:

                                  By:
                                     -------------------------------------------
                                  Name:
                                  Title:

                                   Page 2 of 2
                                   EXHIBIT G-3
<Page>

                            EXHIBIT 1 TO EXHIBIT G-3
                        CERTIFICATE OF GENERAL CONTRACTOR
                 ISSUER'S FINAL DISBURSEMENT REQUEST CERTIFICATE

                                     [Date]

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

Copies to:

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Professional Associates Construction Services
as Independent Construction Consultant
942 East Chapman Avenue
Orange, California 92866
Attention: Kent Robertson

     Re:  Issuer's Final Disbursement Request Certificate dated ______________,
          20__ of Premier Entertainment Biloxi LLC ("PREMIER") and Premier
          Finance Biloxi Corp. ("PFC", and jointly and severally with Premier,
          the "ISSUER")

Ladies and Gentlemen:

     Roy Anderson Corp (the "GENERAL CONTRACTOR") hereby certifies as follows:

     (a)  The General Contractor has reviewed the above referenced Issuer's
Final Disbursement Request Certificate and the Cash Collateral and Disbursement
Agreement dated as of January 23, 2004 (the "AGREEMENT"), to which the Issuer is
a party, to the extent necessary to understand the defined terms contained
herein and therein that are incorporated by reference from the Agreement and to
provide the certification contained herein. Capitalized terms used herein and
not otherwise defined shall have the meanings ascribed to them in the Agreement.

                                   Page 1 of 2
                            EXHIBIT 1 TO EXHIBIT G-3
<Page>

     (b)  The General Contractor hereby certifies and confirms the accuracy of
each of the certifications contained in Paragraphs (b) and (c); PROVIDED,
HOWEVER, that with respect to Paragraphs (b) and (c) solely as to Contractors
other than the General Contractor and Contractors party to the "Direct Purchase
Items" (as defined in the GMP Contract), this certification is limited to the
best of the General Contractor's Knowledge.

          The Issuer, the Disbursement Agent, the Trustee and the Independent
Construction Consultant are entitled to rely on the foregoing representations,
warranties and certifications in authorizing and making the disbursement
requested in the Issuer's Final Disbursement Request Certificate.

                                         ROY ANDERSON CORP

                                         By:
                                            ------------------------------------
                                         Name:
                                         Title:

                                   Page 2 of 2
                            EXHIBIT 1 TO EXHIBIT G-3
<Page>

                            EXHIBIT 2 TO EXHIBIT G-3
               CERTIFICATE OF INDEPENDENT CONSTRUCTION CONSULTANT
                 ISSUER'S FINAL DISBURSEMENT REQUEST CERTIFICATE
                                     [Date]

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

Copies to:

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Re:  Issuer's Final Disbursement Request Certificate dated __________, 20__
     Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance Biloxi
     Corp. ("PFC", and jointly and severally with Premier, the "ISSUER")

Ladies and Gentlemen:

     Professional Associates Construction Services, Inc. (the "INDEPENDENT
CONSTRUCTION CONSULTANT") hereby certifies as follows:

     (a)  The Independent Construction Consultant has reviewed the above
referenced Issuer's Request Disbursement Certificate and the Cash Collateral and
Disbursement Agreement dated as of January 23, 2004 (the "AGREEMENT"), to which
the Issuer and the undersigned are a party to the extent necessary to understand
the defined terms contained herein and in the Issuer's Final Disbursement
Request Certificate that are incorporated by reference from the Agreement, and
to provide the certification contained herein. Capitalized terms used herein and
not otherwise defined shall have the meaning ascribed to them in the Agreement.

     (b)  The Independent Construction Consultant hereby certifies and confirms
the accuracy of the certifications contained in Paragraph (a), (b) (to the best
of its Knowledge), and (c) of the above-referenced Issuer's Final Disbursement
Request Certificate.

                                   Page 1 of 2
                            EXHIBIT 2 TO EXHIBIT G-3
<Page>

     (c)  The Independent Construction Consultant last inspected the Facility
on _________.

     The Disbursement Agent, the Trustee and the Issuer are entitled to rely on
the foregoing representations, warranties and certifications.

                                         PROFESSIONAL ASSOCIATES CONSTRUCTION
                                         SERVICES, INC.

                                         By:
                                            ------------------------------------
                                         Name:
                                         Title:

                                   Page 2 of 2
                            EXHIBIT 2 TO EXHIBIT G-3
<Page>

            EXHIBIT G-4 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
            FORM OF TIDELANDS LEASE DISBURSEMENT REQUEST CERTIFICATE

                                __________, 20__

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

Copies to:

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

     Re:  Cash Collateral and Disbursement Agreement
          Tidelands Lease Disbursement Request Certificate

Ladies and Gentlemen:

     This certificate is delivered to you pursuant to SECTION 6 of that certain
Cash Collateral and Disbursement Agreement dated as of January 23, 2004 (the
"AGREEMENT"), to which the Disbursement Agent is a party. Capitalized terms used
in this certificate that are otherwise not defined shall have the meanings
assigned to them in the Agreement. In connection with the requested
disbursements, the Issuer hereby represents, warrants and certifies as follows:

     (a)  Premier Entertainment Biloxi LLC, a Delaware limited liability company
("PREMIER") hereby requests that you, in your capacity as Disbursement Agent
under the Agreement, distribute checks drawn on, or wire transfer from, the
Tidelands Lease Account to the Mississippi Secretary of State (the "PAYEE") in
the following amount: $_____________. Premier hereby irrevocably instructs the
Disbursement Agent, in accordance with SECTION 4.8 of the Agreement, to disburse
the requested amounts from the Tidelands Lease Account on behalf of Premier, to
the attention of the Assistant Secretary of State for Public Lands in the Office
of the Secretary of State in Jackson, Mississippi, 401 Mississippi Street,
Jackson, Mississippi 39201-1004 or to such other address specified by written
notice from the Secretary of State pursuant to SECTION [ ] of the Tidelands
Lease.

                                   Page 1 of 2
                                   EXHIBIT G-4
<Page>
     (b)  Premier certifies that the requested amount herein is required to be
paid to the Payee pursuant to the provisions of the Tidelands Lease.

     The Disbursement Agent is entitled to rely on the foregoing
representations, warranties and certifications in authorizing and making the
disbursement requested above.

                                         PREMIER ENTERTAINMENT BILOXI LLC, a
                                         Delaware limited liability company(1)

                                         By:
                                            ------------------------------------
                                         Name:
                                         Title:

                                         By:
                                            ------------------------------------
                                         Name:
                                         Title:

----------
(1)  [After Initial Operating Date, this certificate must be signed by two
     officers of Premier, one of whom must be the principal executive officer,
     the principal financial officer, the treasurer or the principal accounting
     officer of Premier.]

                                   Page 2 of 2
                                   EXHIBIT G-4
<Page>

            EXHIBIT H-1 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
      LONG FORM OF CONSENT TO SECURITY ASSIGNMENT OF CONSTRUCTION CONTRACT
                           (CONTRACTS OVER $1,000,000)

                              CONSENT AND AGREEMENT
                          (OWNER CONTRACTOR AGREEMENT)

          This CONSENT AND AGREEMENT (OWNER CONTRACTOR AGREEMENT) (the
"CONSENT"), dated as of [___________], 2004, is executed by [________________],
a [______________________] (the "UNDERSIGNED"), PREMIER ENTERTAINMENT BILOXI LLC
(d/b/a Hard Rock Hotel & Casino Biloxi), a Delaware limited liability company
("PREMIER"), and U.S. BANK NATIONAL ASSOCIATION, a national banking association,
as trustee under the Indenture (as defined below) (together with its successors
and assigns from time to time under the Indenture, the "TRUSTEE").

                                    RECITALS

          A.     THE FACILITY. Premier proposes to develop, construct and
operate the Hard Rock Hotel & Casino Biloxi, a full service gaming, hotel and
entertainment resort and certain related amenities to be developed upon
approximately 8.5 acres along the Mississippi Gulf Coast in Biloxi, Mississippi
(the "FACILITY").

          B.     FIRST MORTGAGE NOTES. Concurrently herewith, Premier and
Premier Finance Biloxi Corp, a Delaware corporation ("PFC" and together with
Premier, the "ISSUER") is issuing $160,000,000 aggregate principal amount of its
10 3/4% First Mortgage Notes due 2012 together with all other notes issued under
the Indenture, including all notes issued in exchange or replacement thereof,
the "FIRST MORTGAGE NOTES"), pursuant to that certain Indenture dated as of
January 23, 2004, among the Issuer and the Trustee (as amended, modified or
supplemented from time to time, the "INDENTURE"), to finance Project Costs. The
first priority liens in favor of the Trustee on behalf of the holders from time
to time of the First Mortgage Notes (collectively, the "SECURED PARTIES")

          C.     OWNER CONTRACTOR AGREEMENT. The Undersigned and Premier have
entered into that certain [Agreement Between Owner and Contractor] dated as of
[_____________], 20____, pursuant to which the Undersigned has agreed to
[___________________________] in connection with the Facility (as amended and
supplemented or modified from time to time in accordance with its terms and the
terms hereof, the "CONTRACT").

          D.     SECURITY AGREEMENT. Pursuant to that certain Pledge and
Security Agreement dated as of January 23, 2004 (the "SECURITY AGREEMENT"), by
and between Premier, PFC, the Trustee and the other parties named therein,
Premier has collaterally assigned its interest under the contracts between
Premier and any person pertaining to the construction of the Facility, including
the GMP Contract (the "CONSTRUCTION CONTRACTS") to the Trustee on behalf of the
Secured Parties.

                                    AGREEMENT

          NOW THEREFORE, the Parties hereby agree as follows:

          1.     The Undersigned consents to Premier's transfer, assignment, and
grant of a security interest in and to the Contract, as provided for in the
Security Agreement.

                                   Page 1 of 8
                                   EXHIBIT H-1
<Page>

          2.     The Trustee shall be entitled (but not obligated) to cure any
defaults of Premier under the Contract. Upon receipt of notice from the Trustee,
the Undersigned agrees to accept such cure by the Trustee.

          3.     The Undersigned will not, without the prior written consent of
the Trustee, (i) cancel or terminate the Contract except as provided in the
Contract and in accordance with SECTION 4 hereof, or consent to or accept any
cancellation, termination or suspension thereof by Premier, (ii) sell or assign
any part of its interest in the Contract; or (iii) amend or modify the Contract
in any material respect unless a Construction Contract Amendment Certificate has
been delivered by Premier pursuant to SECTION 5.2 of the Cash Collateral and
Disbursement Agreement entered into among the Issuer, the Trustee, such
construction consultant and a disbursement agent thereunder (the "DISBURSEMENT
AGREEMENT").

          4.     The Undersigned will not terminate the Contract on account of
any default or breach of Premier thereunder without written notice to the
Trustee and first providing to the Trustee (i) ninety (90) days from the date
notice of default or breach is delivered to the Trustee to cure such default if
such default is the failure to pay amounts to the Undersigned which are due and
payable under the Contract or (ii) a reasonable opportunity, but not fewer than
one hundred twenty (120) days, to cure such breach or default if the breach or
default cannot be cured by the payment of money to the Undersigned. If
possession of the Facility is necessary to cure such breach or default and the
Trustee or its designee(s) or assignee(s) declare Premier in default and
commence foreclosure proceedings, the Trustee or its designee(s) or assignee(s),
will be allowed a reasonable period to complete such proceedings. If the Trustee
or its designee(s) or assignee(s) are prohibited by any court order or
bankruptcy or insolvency proceedings from curing the default or from commencing
or prosecuting foreclosure proceedings, the foregoing time periods shall be
extended by the period of such prohibition, but such extension shall not exceed
one hundred and fifty (150) days beyond the time frames set out in clause (ii)
of the first sentence of this SECTION 4.

          5.     The Undersigned consents to the transfer of Premier's interest
under the Contract to (i) the Secured Parties or any of them or (ii) a purchaser
or grantee at a foreclosure sale by judicial or nonjudicial foreclosure and sale
or by a conveyance by Premier in lieu of foreclosure (any such purchaser or
grantee, other than the Secured Parties, shall be referred to herein as a "THIRD
PARTY TRANSFEREE"). The Undersigned agrees that upon such foreclosure, sale or
conveyance, the Undersigned shall recognize such Secured Party or Third Party
Transferee as the applicable party under the Contract (provided that such
Secured Party or Third Party Transferee assumes the obligations of Premier under
the Contract and provided further that such Secured Party or Third Party
Transferee is creditworthy). "Assume the obligations of Premier under the
Contract" shall mean the assumption by such Secured Party or Third Party
Transferee of all obligations of Premier under the Contract, regardless of
whether for past or future matters, and specifically, but not by way of
limitation, shall require simultaneous payment of all amounts owed and
acknowledgement of liability for all amounts becoming owed, all as a condition
of the Undersigned's obligation to accept such assumption and to accept
instructions from such Secured Party or Third Party Transferee. A Third Party
Transferee or Secured Party shall be deemed creditworthy if either (a) it has a
net worth of at least $20 million dollars (calculated in accordance with
generally accepted accounting principals in effect from time to time in the
United States); or (b) it has been approved as creditworthy by Undersigned, it
being understood that the Undersigned shall not unreasonably withhold, delay or
condition its approval and shall take into account the net worth of such Secured
Party or Third Party Transferee and any letter of credit or other credit
instrument proposed to be made available as security for the performance of such
Third Party Transferee.

          6.     If the Trustee gives written notice to the Undersigned that an
event of default has occurred under any of the agreements with the Secured
Parties (the "TRANSACTION DOCUMENTS") and requests that the Undersigned continue
its performance under the Contract, then the Undersigned shall

                                   Page 2 of 8
                                   EXHIBIT H-1
<Page>

thereafter perform for the Secured Parties under the Contract in accordance with
its terms so long as the Undersigned shall be paid all amounts as and when
required under the Contract, including payment of any sums due to the
Undersigned for work performed up to and including the date of Premier's default
and thereafter, with said request constituting such an agreement by the Trustee
on behalf of one or more of the Secured Parties to so pay the Undersigned in
accordance with the Contract. The Undersigned shall have the right to refuse to
continue performance of the Contract unless and until the Undersigned has been
paid in full for all amounts then due under the Contract. The Undersigned shall
render such performance to the Secured Parties notwithstanding any contrary
directions, instructions or assertions from Premier. Premier hereby authorizes
and directs the Undersigned to render such performance to the Secured Parties as
contemplated herein.

          7.     In the event that the Contract is rejected by a trustee or
debtor-in possession in any bankruptcy or insolvency proceeding, and if, within
sixty (60) days after such rejection, the Secured Parties or their successors or
assigns shall so request, the Undersigned will execute and deliver to the
Secured Parties or their designee or assignee (if creditworthy as defined
herein) a new Construction Contract, which Construction Contract shall be on the
same terms and conditions as the original Contract, subject to such extensions
of time and additional compensation as may be appropriate under the
circumstances. However, as a condition precedent to the Undersigned's
obligations to execute and deliver any such new Construction Contract, Secured
Parties shall pay all previously unpaid sums owed to the Undersigned under the
original Contract.

          8.     The parties recognize and agree that the events contemplated in
SECTIONS 1, 2, 3, 4, 5, 6, and 7 may lead to or involve time delays and
increased costs as to the Undersigned's performance under the Contract, and,
therefore, the Undersigned must be granted such extensions of time and
additional compensation as may be appropriate due to actual impacts of the
circumstances contemplated herein.

          9.     In the event the Secured Parties or their designee(s) or
assignee(s) elect to perform Premier's obligations under the Contract and cure
any default by Premier under the Contract as provided in SECTIONS 2 and 4 above
(and not under SECTIONS 5, 6, 7, or 10 herein), the Secured Parties, their
designee(s) and assignee(s), shall have no personal liability to the Undersigned
for the performance of such obligations, and the sole recourse of the
Undersigned in seeking the enforcement of such obligations shall be to such
parties' interest in the Facility; however, this limitation on personal
liability shall not apply as to actions by the Secured Parties or their
designee(s) or assignee(s) under SECTIONS 5, 6, 7, or 10 herein. Notwithstanding
the foregoing or any foreclosure of the Facility by the Secured Parties, the
Undersigned shall retain any and all of its rights and claims against Premier.

          10.    In the event the Secured Parties or their designee(s) or
assignee(s) succeed to Premier's interest under the Contract, the Secured
Parties shall have the right to assign all or a pro rata interest in the
Contract or a new Construction Contract entered into pursuant to SECTION 7 to a
person or entity to whom the Facility is transferred, provided such transferee
assumes the obligations of Premier (or the Secured Parties) under the Contract.
Upon such assignment, the Trustee and, if applicable, the Secured Parties
(including their agents and employees) shall be released from any further
liability thereunder to the extent of the interest assigned, upon the following
conditions: (i) the assignee must be a party as to whom the Undersigned does not
have a reasonable objection, including, but not limited to, as to the
creditworthiness (as defined in SECTION 5 above) of the assignee; (ii) all sums
due to the Undersigned as of the time it received notice of that assignment or
as of the time such assignment takes place (whichever is later) are paid in
full; and (iii) the assignee must acknowledge, upon terms and conditions
acceptable to Undersigned, liability for all sums due and owing and becoming due
and owing thereafter and for all other obligations under the Contract,
including, but not limited to obligations as to the issues addressed by SECTION
8.

                                   Page 3 of 8
                                   EXHIBIT H-1
<Page>

          11.    The warranties provided by the Undersigned under the Contract
shall continue in full force and effect (until the expiration of the warranty
periods set forth in the Contract) in the event that the Secured Parties or
their designee(s) or assignee(s) succeed to Premier's interest in the Contract
(whether by foreclosure, sale or other assignment) and upon the further
assignment or sale of the Contract by the Secured Parties or their designee(s)
or assignee(s).

          12.    The Undersigned hereby assigns to Premier (and Premier's
assigns) all its interest in any subcontracts and purchase orders now existing
or hereinafter entered into by the Undersigned for performance of any part of
the Undersigned's obligations under the Contract (the "SUBCONTRACTS"). Such
assignment shall be effective only upon the termination of the Contract for the
default of the Undersigned, and then only as to those Subcontracts which Premier
(or its assigns) at such time accepts in writing. The Undersigned also grants a
security interest to Premier (and Premier's assigns) in all of its interest in
such Subcontracts as security for the performance of the Undersigned's
obligations under the Contract. The Undersigned further assigns to Premier (and
Premier's assigns) all of its rights with respect to any warranties under the
Subcontracts, such assignment shall be effective upon the termination of the
Contract for the default of the Undersigned.

          13.    The Undersigned hereby agrees (i) to cooperate with
Professional Associates Construction Services, Inc. or any other person
designated from time to time by the Trustee to serve as construction consultant
under the Disbursement Agreement (the "INDEPENDENT CONSTRUCTION CONSULTANT") to
facilitate performance of its duties to monitor the progress of the construction
of the Facility, (ii) to, upon request, deliver to the Independent Construction
Consultant copies of any notices and progress reports delivered to Premier
pursuant to the Contract, (iii) to meet with the Independent Construction
Consultant to discuss the status and progress of construction of the Facility
whenever reasonably requested by the Independent Construction Consultant and
(iv) to allow the Independent Construction Consultant the opportunity to be
included in all material meetings between the Undersigned and Premier related to
the construction of the Facility. However, this shall not prohibit the
Undersigned from moving forward with any meeting when the circumstances
surrounding such meeting make it unreasonable to await involvement by the
Independent Construction Consultant.

          14.    The Undersigned hereby represents, warrants and certifies that:

                 (a)  The execution, delivery and performance by the Undersigned
of the Contract and this Consent has been duly authorized by all necessary
corporate action, and does not and will not require any further consents or
approvals which have not been obtained, or violate any provision of any law,
regulation, order, judgment, injunction or similar matters or breach any
agreement presently in effect with respect to or binding on the Undersigned
(except as to assignments of Subcontracts set forth in SECTION 12).

                 (b)  This Consent and the Contract are legal, valid and binding
obligations of the Undersigned, enforceable against the Undersigned in
accordance with their respective terms.

                 (c)  The Undersigned has delivered to the Trustee a true and
correct copy of the Contract including all amendments and modifications thereto,
up to the date hereof. As of the date hereof, the Contract is in full force and
effect and constitutes the only agreement between the Undersigned and Premier
with respect to the matters and interest described therein.

          15.    All Notices required or permitted hereunder shall be in writing
and shall be effective (a) upon receipt if hand delivered, (b) upon receipt if
sent by facsimile and (c) if otherwise delivered, upon the earlier of receipt or
two (2) business days after being sent registered or certified mail,

                                   Page 4 of 8
                                   EXHIBIT H-1
<Page>

return receipt requested, with proper postage affixed thereto, or by private
courier or delivery service with charges prepaid, and addressed as specified
below:

                      If to the Undersigned:

                      ______________________________
                      ______________________________
                      ______________________________
                      Attn:_________________________
                      Telecopy No.:_________________
                      Facsimile No.:________________

                      If to the Trustee:

                      U.S. Bank National Association,
                      as Disbursement Agent
                      60 Livingston Avenue
                      St. Paul, MN 55107-2292
                      Attn: Frank Leslie
                      Telephone No.: (651) 495-3913
                      Telecopy No.: (651) 495-8097

                      If to Premier:

                      Premier Entertainment Biloxi LLC
                      11400 Reichold Road
                      Gulfport, MS 39503
                      Attn: Joseph Billhimer
                      Telecopy No.: (228) 594-4021
                      Telephone No.: (228) 896-4078

                      With a copy to:

                      Duane Morris LLP
                      227 West Monroe Street, Suite 3400
                      Chicago, Illinois 60606
                      Attention: Brian P. Kerwin, Esq.
                      Telecopy No.: (312) 499-6701
                      Telephone No.: (312) 499-6701

          16.    This Consent shall be binding upon and inure to the benefit of
the Undersigned, the Trustee, Premier, PFC, the Secured Parties and their
respective successors, transferees and assigns (including without limitation,
any entity that refinances all or any portion of the Obligations). No
termination, amendment, variation or waiver of any provisions of this Consent
shall be effective unless in writing and signed by the Undersigned, the Trustee,
Premier and PFC. This Consent shall be governed and construed in accordance by
the internal laws of the State of Mississippi.

          17.    This Consent may be executed in one or more duplicate
counterparts, and when executed and delivered by all the parties listed below,
shall constitute a single binding agreement.

                                   Page 5 of 8
                                   EXHIBIT H-1
<Page>

          18.    All references in this Consent to any document, instrument or
agreement (a) shall include all exhibits, schedules and other attachments
thereto, (b) shall include all documents, instruments or agreements issued or
executed in replacement thereof, and (c) shall mean such document, instrument or
agreement, or replacement or predecessor thereto, as amended, modified and
supplemented from time to time and in effect at any given time.

                  [REMAINDER OF PAGE INTENTIONALLY LEFT BLANK]

                                   Page 6 of 8
                                   EXHIBIT H-1
<Page>

          IN WITNESS WHEREOF, the Undersigned by its officer thereunto duly
authorized, has duly executed this Consent as of the date first set forth above.

                                    [__________________________],
                                    a [______________________]

                                    By:
                                           -------------------------------------
                                    Name:
                                           -------------------------------------
                                    Title:
                                           -------------------------------------

                                    PREMIER ENTERTAINMENT BILOXI LLC,
                                    (d/b/a Hard Rock Hotel & Casino Biloxi),
                                    a Delaware limited liability company

                                    By:
                                           -------------------------------------
                                    Name:
                                           -------------------------------------
                                    Title:
                                           -------------------------------------

ACKNOWLEDGED AND AGREED:

U.S. BANK NATIONAL ASSOCIATION,
a national banking association,
as Trustee

By:
      --------------------------------
      Name:
            --------------------------
      Title:
            --------------------------

                                   Page 8 of 8
                                   EXHIBIT H-1
<Page>

            EXHIBIT H-2 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
     SHORT FORM OF CONSENT TO SECURITY ASSIGNMENT OF CONSTRUCTION CONTRACT
                   (CONTRACTS BETWEEN $500,000 AND $1,000,000)

                              CONSENT AND AGREEMENT

          This CONSENT AND AGREEMENT (the "CONSENT"), dated as of [___________],
2004, is executed by [____________________], a [______________________], located
at (the "UNDERSIGNED"), PREMIER ENTERTAINMENT BILOXI LLC (d/b/a Hard Rock Hotel
& Casino Biloxi), a Delaware limited liability company, located at 11400
Reichold Road, Gulfport, MS 39503 ("PREMIER"), and U.S. BANK NATIONAL
ASSOCIATION, a national banking association, as trustee under the Indenture,
located at 60 Livingston Avenue, St. Paul, MN 55107-2292, as defined below
(together with its successors and assigns from time to time under the Indenture,
the "TRUSTEE") for the benefit of the holders from time to time of the First
Mortgage Notes (as defined below) (collectively, with the Trustee, the "SECURED
PARTIES")

          A.     THE FACILITY. Premier proposes to develop, construct and
operate the Hard Rock Hotel & Casino Biloxi, a full service gaming, hotel and
entertainment resort and certain related amenities to be developed upon
approximately 8.5 acres along the Mississippi Gulf Coast in Biloxi, Mississippi
(the "FACILITY").

          B.     FIRST MORTGAGE NOTES. Concurrently herewith, Premier and
Premier Finance Biloxi Corp., a Delaware corporation ("PFC," and together with
Premier, the "ISSUER") is issuing $160,000,000 aggregate principal amount of its
10 3/4% First Mortgage Notes due 2012 (together with all other notes issued
under the Indenture, including all notes issued in exchange or replacement
thereof, the "FIRST MORTGAGE NOTES"), pursuant to that certain Indenture dated
as of January 23, 2004, among the Issuer and the Trustee (as amended, modified
or supplemented from time to time, the "INDENTURE"), to finance Project Costs.

          C.     [CONTRACT]. The Undersigned and Premier have entered into that
certain Agreement Between Owner and Contractor dated as of [ ], 20 , pursuant to
which the Undersigned has agreed to [ ][DESCRIBE WORK OR SERVICES TO BE
PERFORMED UNDER THIS CONTRACT] in connection with the Facility (as amended,
supplemented or modified from time to time in accordance with its terms and the
terms hereof, the "CONTRACT").

          D.     SECURITY AGREEMENT. Pursuant to that certain Pledge and
Security Agreement dated as of January 23, 2004 (the "SECURITY AGREEMENT"), by
and between Premier, PFC, the Trustee and the other parties named therein,
Premier has collaterally assigned its interest under the contracts between
Premier and any person pertaining to the construction of the Facility, including
the Contract (the "CONSTRUCTION CONTRACTS") to the Trustee on behalf of the
Secured Parties.

          NOW THEREFORE, the Parties hereby agree as follows:

          1.     The Undersigned consents to Premier's transfer, assignment, and
grant of a security interest in and to the Contract, as provided for in the
Security Agreement.

          2.     The Trustee shall be entitled (but not obligated) to cure any
defaults of Premier under the Contract. Upon receipt of notice from the Trustee,
the Undersigned agrees to accept such cure by the Trustee.

          3.     The Undersigned will not, without the prior written consent of
the Trustee, (i) cancel or terminate the Contract except as provided in the
Contract and in accordance with SECTION 4

                                   Page 1 of 1
                                   EXHIBIT H-2
<Page>

hereof, or consent to or accept any cancellation, termination or suspension
thereof by Premier, (ii) sell or assign any part of its interest in the
Contract, or (iii) amend or modify the Contract in any material respect unless a
Construction Contract Amendment Certificate has been delivered by Premier
pursuant to SECTION 5.2 of the Cash Collateral and Disbursement Agreement
entered into among the Issuer, the Trustee, such construction consultant and a
disbursement agent thereunder).

          4.     The Undersigned will not terminate the Contract on account of
any default or breach of Premier thereunder without written notice to the
Trustee and first providing to the Trustee a reasonable opportunity, but not
fewer than one hundred twenty (120) days, to cure such breach or default if the
breach or default cannot be cured by the payment of money to the Undersigned. If
possession of the Facility is necessary to cure such breach or default and the
Trustee or its designee(s) or assignee(s) declare Premier in default and
commence foreclosure proceedings, the Trustee or its designee(s) or assignee(s),
will be allowed a reasonable period to complete such proceedings. If the Trustee
or its designee(s) or assignee(s) are prohibited by any court order or
bankruptcy or insolvency proceedings from curing the default or from commencing
or prosecuting foreclosure proceedings, the foregoing time periods shall be
extended by the period of such prohibition, but such extension shall not exceed
one hundred and fifty (150) days beyond the time frames set out in clause (ii)
of the first sentence of this SECTION 4.

          5.     The Undersigned consents to the transfer of Premier's interest
under the Contract to (i) the Secured Parties or any of them or (ii) a purchaser
or grantee at a foreclosure sale by judicial or nonjudicial foreclosure and sale
or by a conveyance by Premier in lieu of foreclosure. Upon such foreclosure,
sale or conveyance, the Undersigned shall recognize such party as the applicable
party under the Contract.

          6.     If the Trustee gives written notice to the Undersigned that an
event of default has occurred under any of the agreements with the Secured
Parties and requests that the Undersigned continue its performance under the
Contract, then the Undersigned shall thereafter perform for the Secured Parties
under the Contract in accordance with its terms so long as the Undersigned shall
be paid all amounts as and when required under the Contract.

          7.     In the event that the Contract is rejected by a trustee or
debtor-in possession in any bankruptcy or insolvency proceeding, and if, within
sixty (60) days after such rejection, the Secured Parties or their successors or
assigns shall so request, the Undersigned will execute and deliver to the
Secured Parties or their designee or assignee a new Construction Contract, which
Construction Contract shall be on the same terms and conditions as the original
Contract, subject to such extensions of time and additional compensation as may
be appropriate under the circumstances.

          8.     In the event the Secured Parties or their designee(s) or
assignee(s) elect to perform Premier's obligations under the Contract and cure
any default by Premier under the Contract, the Secured Parties, their
designee(s) and assignee(s), shall have no personal liability to the Undersigned
for the performance of such obligations, and the sole recourse of the
Undersigned in seeking the enforcement of such obligations shall be to such
parties' interest in the Facility. If the Secured Parties or their designee(s)
or assignee(s) (succeeding to Premier's interests under the Contract) assign all
or a pro rata interest in its rights and obligations under the Contract or new
Construction Contract to a person or entity to whom the Facility is transferred,
then the Trustee and the Secured Parties (including their agents and employees)
shall be released from all further liability thereunder.

          9.     The warranties provided by the Undersigned under the Contract
shall continue in full force and effect (until the expiration of the warranty
periods set forth in the Contract) in the event that

                                   Page 2 of 4
                                   EXHIBIT H-2
<Page>

the Secured Parties or their designee(s) or assignee(s) succeed to Premier's
interest in the Contract (whether by foreclosure, sale or other assignment) and
upon the further assignment or sale of the Contract by the Secured Parties or
their designee(s) or assignee(s).

          10.    The Undersigned hereby assigns to Premier (and Premier's
assigns) all its interest in any subcontracts and purchase orders now existing
or hereinafter entered into by the Undersigned for performance of any part of
the Undersigned's obligations under the Contract (the "Subcontracts"). Such
assignment shall be effective only upon the termination of the Contract for the
default of the Undersigned, and then only as to those Subcontracts which Premier
(or its assigns) at such time accepts in writing. The Undersigned also grants a
security interest to Premier (and Premier's assigns) in all of its interest in
such Subcontracts as security for the Undersigned's obligations under the
Contract.

          11.    The Undersigned hereby represents, warrants and certifies that
the Undersigned has delivered to the Trustee a true and correct copy of the
Contract including all amendments and modifications thereto, up to the date
hereof. As of the date hereof, the Contract is in full force and effect and
constitutes the only agreement between the Undersigned and Premier with respect
to the matters and interest described therein.

          12.    This Consent shall be binding upon and inure to the benefit of
the Undersigned, the Trustee, Premier, PFC, the Secured Parties and their
respective successors, transferees and assigns (including without limitation,
any entity that refinances all or any portion of the Obligations). The
Undersigned agrees to confirm such continuing obligation in writing upon the
reasonable request of Premier, PFC, the Trustee, the Secured Parties or any of
their respective successors, transferees or assigns. No termination, amendment,
variation or waiver of any provisions of this Consent shall be effective unless
in writing and signed by the Undersigned, the Trustee, Premier and PFC. This
Consent shall be governed and construed in accordance by the internal laws of
the State of Mississippi. This Consent may be executed in one or more duplicate
counterparts, and when executed and delivered by all the parties listed below,
shall constitute a single binding agreement.

          IN WITNESS WHEREOF, the Undersigned by its officer thereunto duly
authorized, has duly executed this Consent as of the date first set forth above.

                                    [__________________________],
                                    a [______________________]

                                    By:
                                           -------------------------------------
                                    Name:
                                           -------------------------------------
                                    Title:
                                           -------------------------------------

                                    PREMIER ENTERTAINMENT BILOXI LLC,
                                    (d/b/a Hard Rock Hotel & Casino Biloxi),
                                    a Delaware limited liability company

                                    By:
                                           -------------------------------------
                                    Name:
                                           -------------------------------------
                                    Title:
                                           -------------------------------------

                                   Page 3 of 4
                                   EXHIBIT H-2
<Page>

ACKNOWLEDGED AND AGREED:

U.S. BANK NATIONAL ASSOCIATION,
a national banking association,
as Trustee

By:
      -------------------------------
      Name:
            --------------------------
      Title:
            --------------------------

                                   Page 4 of 4
                                   EXHIBIT H-2
<Page>

             EXHIBIT I TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
                             INITIAL PROJECT BUDGET
                             Date: [________], 2004
                              [ISSUER TO PROVIDE]

                                  Page 1 of __
                                    EXHIBIT I
<Page>

            EXHIBIT J TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
                        FINAL PLANS AMENDMENT CERTIFICATE

                                     [DATE]

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Copies to:

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Professional Associates Construction Services
as Independent Construction Consultant
942 East Chapman Avenue
Orange, California 92866
Attention: Kent Robertson

Re:  Amendment of Final Plans

Ladies and Gentlemen:

     The Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance Biloxi
Corp. ("PFC", and jointly and severally with Premier, the "ISSUER"), requests
that the Final Plans for the Facility be amended to include the Plans described
on SCHEDULE 3 to this certificate. This certificate is delivered pursuant to
SECTION 5.6 of that certain Cash Collateral and Disbursement Agreement dated as
of January 23, 2004 (the "AGREEMENT"), to which the Disbursement Agent is a
party. Capitalized terms used in this certificate that are otherwise not defined
shall have the meaning assigned in the Agreement. In connection with the
requested Final Plans amendment, the Issuer hereby represents, warrants and
certifies as follows:

     (a)  The Preliminary Plans for the Facility as of the date hereof are
described on SCHEDULE 1 and the Final Plans for the Facility as of the date
hereof are described on SCHEDULE 2. The Plans set forth in SCHEDULE 3, with
respect to any particular work or improvement:

          (i)    have received all approvals from all governmental authorities
     required to approve such Plans necessary to commence construction of such
     work or improvements described therein;

                                   Page 1 of 3
                                    EXHIBIT J
<Page>

          (ii)   contain sufficient specificity to permit completion of such
     work or improvement described therein;

          (iii)  are consistent with constructing the Facility to include the
     Minimum Facilities;

          (iv)   have been signed by an architect licensed to practice
     architecture in the State of Mississippi;

          (v)    call for construction of the Facility in a manner consistent
     with the Initial Operating Date occurring on or prior to the Operating
     Deadline; and

          (vi)   have been delivered to the Independent Construction Consultant
     and the Disbursement Agent.

     (b)  To the Issuer's Knowledge (but without any duty of inquiry), the
construction performed as of the date hereof is substantially in accordance with
the Final Plans. The Issuer reasonably believes that the Initial Operating Date
will occur on or prior to the Operating Deadline.

     (c)  After giving effect to this proposed amendment to the Final Plans and
any concurrent amendment to the Project Budget, the Project Budget accurately
sets forth in all material respects the anticipated Construction Expenses
through completion of the construction of the Facility, allocated among the
various line item components thereof identified on the Project Budget in effect
on the Issuance Date.

     (d)  As of the date hereof, no Event of Default exists, and this proposed
amendment to the Final Plans and any concurrent amendment to the Project Budget
will not constitute, result in, nor create an Event of Default.

     The Disbursement Agent, the Trustee and the Independent Construction
Consultant are entitled to rely on the foregoing representations, warranties and
certifications.

     The undersigned certifies that this Final Plans Amendment Certificate is
authorized hereby and is permitted pursuant to the Agreement and the Indenture
and all conditions precedent thereto have been met.

     Attached to this Final Plans Amendment Certificate as EXHIBITS 1 to 3 are
certificates of the General Contractor (only to the extent the amendment to the
Final Plans relates to the GMP Contract), the Independent Construction
Consultant and the Architect (only to the extent the amendment to the Final
Plans affects that portion of the Facility constructed pursuant to Plans
prepared by it).

                                 PREMIER ENTERTAINMENT BILOXI LLC,

                                   Page 2 of 3
                                    EXHIBIT J
<Page>

                                 on behalf of itself and Premier Finance Biloxi
                                 Corp., as Issuer(1)

                                 By:
                                    --------------------------------------------
                                 Name:
                                 Title:

                                 By:
                                    --------------------------------------------
                                 Name:
                                 Title:

----------
(1)  [After Initial Operating Date, this certificate must be signed by two
     officers of Premier, one of whom must be the principal executive officer,
     the principal financial officer, the treasurer or the principal accounting
     officer of Premier.]

                                   Page 3 of 3
                                    EXHIBIT J
<Page>

                             SCHEDULE 1 TO EXHIBIT J
                        DESCRIPTION OF PRELIMINARY PLANS

                                   Page 1 of 1
                             SCHEDULE 1 TO EXHIBIT J
<Page>

                             SCHEDULE 2 TO EXHIBIT J
                           DESCRIPTION OF FINAL PLANS

                                   Page 1 of 1
                             SCHEDULE 2 TO EXHIBIT J
<Page>

                             SCHEDULE 3 TO EXHIBIT J

Amendment No. __ to Final Plans.

I.   The following describes new Final Plans for any work or improvements to be
included in the Facility and for which no Final Plans currently exist or in
replacement of Preliminary Plans:

<Table>
<Caption>
       Work or Improvement  Architect  Drawing Number
       -------------------  ---------  --------------
<S>    <C>                  <C>        <C>
1.
2.
3.
</Table>

II.  The following describes replacement Final Plans for any work or
improvements to be included in the Facility and for which Final Plans currently
exist:

<Table>
<Caption>
         Work or      Drawing Number of    Architect of    Drawing Number of
       Improvement  Replaced Final Plans  New Final Plans   New Final Plans
       -----------  --------------------  ---------------  -----------------
<S>                 <C>                   <C>              <C>
1.
2.
3.
</Table>

                                   Page 1 of 1
                             SCHEDULE 3 TO EXHIBIT J
<Page>

                             EXHIBIT 1 TO EXHIBIT J
                        CERTIFICATE OF GENERAL CONTRACTOR

                                     [Date]

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

Copies to:

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Professional Associates Construction Services
as Independent Construction Consultant
942 East Chapman Avenue
Orange, California 92866
Attention: Kent Robertson

Re:  Final Plans Amendment Certificate dated __________, 20__
     Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance Biloxi
     Corp. ("PFC", and jointly and severally with Premier, the "ISSUER")

Ladies and Gentlemen:

     Roy Anderson Corp (the "GENERAL CONTRACTOR") hereby certifies as follows:

     (a)  The General Contractor has reviewed the above referenced Final Plans
Amendment Certificate and the Cash Collateral and Disbursement Agreement dated
as of January 23, 2004 (the "AGREEMENT"), to which the Issuer is a party, to the
extent necessary to understand the defined terms contained herein and in the
Final Plans Amendment Certificate that are incorporated by reference from the
Agreement and to provide the certification contained herein. Capitalized terms
used herein and not otherwise defined shall have the meanings ascribed to them
in the Agreement.

                                   Page 1 of 2
                             EXHIBIT 1 TO EXHIBIT J
<Page>

     (b)  The General Contractor hereby certifies and confirms the accuracy of
the certifications contained in (b) and (c) in the above-referenced Final Plans
Amendment Certificate as they apply to that portion of the Facility constructed
pursuant to the GMP Contract (including the "Direct Purchase Items" as defined
in the GMP Contract), provided that where any certification of the Issuer is
limited to the Issuer's Knowledge for the purposes of this certificate, such
certification shall instead be made to the General Contractor's Knowledge.

     The Issuer, the Disbursement Agent, the Trustee and the Independent
Construction Consultant are entitled to rely on the foregoing representations,
warranties and certifications.

                                         ROY ANDERSON CORP

                                         By:
                                            ------------------------------------
                                         Name:
                                         Title:

                                   Page 2 of 2
                             EXHIBIT 1 TO EXHIBIT J
<Page>

                             EXHIBIT 2 TO EXHIBIT J
               CERTIFICATE OF INDEPENDENT CONSTRUCTION CONSULTANT

                                     [Date]

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

Copies to:

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Re:  Final Plans Amendment Certificate dated __________, 20__
     Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance Biloxi
     Corp. ("PFC", and jointly and severally with Premier, the "ISSUER")

Ladies and Gentlemen:

     Professional Associates Construction Services, Inc. (the "INDEPENDENT
CONSTRUCTION CONSULTANT") hereby certifies as follows:

     (a)  The Independent Construction Consultant has reviewed the above
referenced Final Plans Amendment Certificate and the Cash Collateral and
Disbursement Agreement dated as of January 23, 2004 (the "AGREEMENT"), to which
the Issuer and the undersigned are a party, to the extent necessary to
understand the defined terms contained herein and in the Final Plans Amendment
Certificate that are incorporated by reference from the Agreement and to provide
the certification contained herein. Capitalized terms used herein and not
otherwise defined shall have the meanings ascribed to them in the Agreement.

     (b)  The Independent Construction Consultant hereby certifies and confirms
the accuracy of the certifications contained in (a), (b) and (c) of the
above-referenced Final Plans Amendment Certificate; provided that where any
certification of the Issuer is limited to the Issuer's

                                   Page 1 of 2
                             EXHIBIT 2 TO EXHIBIT J
<Page>

Knowledge, for the purposes of this certificate, such certification shall
instead be made to the Independent Construction Consultant's Knowledge or
belief, as applicable.

     (c)  The Independent Construction Consultant last inspected the Facility
on _________.

     The Disbursement Agent, the Trustee and the Issuer are entitled to rely on
the foregoing representations, warranties and certifications.

                                         PROFESSIONAL ASSOCIATES
                                         CONSTRUCTION SERVICES, INC.

                                         By:
                                            ------------------------------------
                                         Name:
                                         Title:

                                   Page 2 of 2
                             EXHIBIT 2 TO EXHIBIT J
<Page>

                             EXHIBIT 3 TO EXHIBIT J
                            CERTIFICATE OF ARCHITECT

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

Copies to:

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Professional Associates Construction Services
as Independent Construction Consultant
942 East Chapman Avenue
Orange, California 92866
Attention: Kent Robertson

Re:  Final Plans Amendment Certificate dated __________, 20__
     Premier Entertainment Biloxi LLC ("PREMIER") and Premier Finance Biloxi
     Corp.
     ("PFC", and jointly and severally with Premier, the "ISSUER")

Ladies and Gentlemen:

     Paul Steelman, Ltd. (the "ARCHITECT") hereby certifies as follows:

     (a)  The Architect has reviewed the above referenced Final Plans Amendment
Certificate and the Cash Collateral and Disbursement Agreement dated as of
January 23, 2004 (the "AGREEMENT"), to which the Issuer is a party, to the
extent necessary to understand the defined terms contained herein and in the
Final Plans Amendment Certificate that are incorporated by reference from the
Agreement and to provide the certification contained herein. Capitalized terms
used herein and not otherwise defined shall have the meaning ascribed to them in
the Agreement.

                                   Page 1 of 3
                             EXHIBIT 3 TO EXHIBIT J
<Page>

     (b)  The Architect hereby certifies and confirms the accuracy of the
certifications contained in (a), (b) and (c) of the above-referenced Final Plans
Amendment Certificate; provided that where any certification of the Issuer is
limited to the Issuer's Knowledge, for the purposes of this certificate, such
certification shall instead be made to the Architect's Knowledge or belief, as
applicable.

     (c)  The Architect last inspected the Facility on _________.

     The Issuer, the Disbursement Agent, the Trustee and the Independent
Construction Consultant are entitled to rely on the foregoing representations,
warranties and certifications.

                                         PAUL STEELMAN, LTD.

                                         By:
                                            ------------------------------------
                                         Name:
                                         Title:

                                   Page 2 of 3
                             EXHIBIT 3 TO EXHIBIT J
<Page>

             EXHIBIT K TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
                  ADDITIONAL CONSTRUCTION CONTRACT CERTIFICATE

                                     [Date]

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Copies to:

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

Professional Associates Construction Services
as Independent Construction Consultant
942 East Chapman Avenue
Orange, California 92866
Attention: Kent Robertson

     Re:  [name of contract] dated ________ (the "CONSTRUCTION CONTRACT"),
          between [______________"Contractor" and] Premier Entertainment Biloxi
          LLC ("PREMIER")

Ladies and Gentlemen:

     This certificate is delivered pursuant to SECTION 5.3 of that certain Cash
Collateral and Disbursement Agreement dated as of January 23, 2004 (the
"AGREEMENT"), to which the Disbursement Agent is a party. Capitalized terms used
and not otherwise defined herein shall have the meanings given in the Agreement.
Premier is entering into the above-referenced Construction Contract, a copy of
which is attached hereto as SCHEDULE 1 (together with a Consent duly executed by
the counterparty to such Construction Contract if and to the extent required
under SECTION 5.3 of the Agreement, a copy of which is attached hereto as
SCHEDULE 2).

     In connection with entering into the Construction Contract, the Premier
hereby represents, warrants and certifies as follows:

     (a)  The work to be performed with respect to the Facility under the
Construction Contract relates to the following line item(s) under the Project
Budget presently in effect and consists of the following:

              ----------------------------------------------------

                                   Page 1 of 2
                                    EXHIBIT K
<Page>

              ----------------------------------------------------
              ----------------------------------------------------

Such work shall conform to the Final Plans.

     (b)  The Construction Contract provides for the Contractor to complete the
work related to the Construction Contract: (i) in a timely manner so as to
permit the Initial Operating Date with respect to the Facility to occur on or
prior to the Operating Deadline; and (ii) within the aggregate amounts specified
for the applicable line item in the Project Budget presently in effect.

     (c)  As of the date hereof, no Event of Default exists, and entering into
the Construction Contract will not constitute, result in, nor create an Event of
Default.

     (d)  The entering into the Construction Contract and the performance of the
work thereunder [WILL/WILL NOT] require an amendment to the Project Budget. [IF
IT WILL, ADD: ATTACHED HERETO IS A DULY COMPLETED AND EXECUTED PROJECT BUDGET
AMENDMENT CERTIFICATE ACCURATELY DESCRIBING SUCH AMENDMENT.]

     The undersigned certifies that this Additional Construction Contract
Certificate is authorized hereby and is permitted pursuant to the Agreement and
the Indenture, and all conditions precedent thereto have been met.

     The Disbursement Agent , the Trustee and the Independent Construction
Consultant are entitled to rely on the foregoing representations, warranties and
certifications.

     Attached to this Additional Construction Contract Certificate as EXHIBIT 1
is a certificate from the Independent Construction Consultant.

                                  PREMIER ENTERTAINMENT BILOXI LLC,
                                  on behalf of itself and Premier Finance Biloxi
                                  Corp., as Issuer(1)

                                  By:
                                     -------------------------------------------
                                  Name:
                                  Title:

                                  By:
                                     -------------------------------------------
                                  Name:

----------
(1)  [After Initial Operating Date, this certificate must be signed by two
     officers of Premier, one of whom must be the principal executive officer,
     the principal financial officer, the treasurer or the principal accounting
     officer of Premier.]

                                   Page 2 of 2
                                    EXHIBIT K
<Page>

                                  Title:

                                   Page 3 of 2
                                    EXHIBIT K
<Page>

                             SCHEDULE 1 TO EXHIBIT K
                     COPY OF EXECUTED CONSTRUCTION CONTRACT

                                   Page 1 of 1
                             SCHEDULE 1 TO EXHIBIT K
<Page>

                             SCHEDULE 2 TO EXHIBIT K
   COPY OF EXECUTED CONSENT TO COLLATERAL ASSIGNMENT OF CONSTRUCTION CONTRACT

                                   Page 1 of 1
                             SCHEDULE 2 TO EXHIBIT K
<Page>

                             EXHIBIT 1 TO EXHIBIT K
               CERTIFICATE OF INDEPENDENT CONSTRUCTION CONSULTANT
                  ADDITIONAL CONSTRUCTION CONTRACT CERTIFICATE

                                     [Date]

Premier Entertainment Biloxi, LLC
11400 Reichold Road
Gulfport, Mississippi 39503
Attn: Joseph Billhimer

Copies to:

U.S. Bank National Association,
as Disbursement Agent
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

U.S. Bank National Association,
as Trustee
60 Livingston Avenue
St. Paul, MN 55107-2292
Attn: Frank Leslie

     Re:  Additional Construction Contract Certificate dated ________, 20__,
          relating to [name of contract] dated __________, _____ (the
          "CONSTRUCTION CONTRACT") between _________________("CONTRACTOR"),
          Premier Entertainment Biloxi LLC ("PREMIER")

Ladies and Gentlemen:

     The undersigned (the "INDEPENDENT CONSTRUCTION CONSULTANT"), hereby
certifies as follows:

     (a)  The Independent Construction Consultant has reviewed the
above-referenced Construction Contract, as well as the above-referenced
Additional Construction Contract Certificate and the Cash Collateral and
Disbursement Agreement dated as of January 23, 2004 (the "AGREEMENT"), to which
Premier and the undersigned are a party. Capitalized terms used and not
otherwise defined herein shall have the meanings given in the Agreement.

     (b)  The Independent Construction Consultant hereby certifies and confirms
the accuracy of the certifications in Paragraphs (a), (b), and (d) of the
above-referenced Additional Construction Contract Certificate; provided that
where any certification of Premier Finance Biloxi Corp. ("PFC", and jointly and
severally with Premier, the "ISSUER") is limited to the Issuer's

                                   Page 1 of 2
                             EXHIBIT 1 TO EXHIBIT K
<Page>

Knowledge for the purpose of this certificate such certification shall instead
be made to the Independent Construction Consultant's Knowledge. The Independent
Construction Consultant is not aware of any material errors in the information
contained in any other paragraph of the Additional Construction Contract
Certificate.

     (c)  The Independent Construction Consultant last inspected the Facility on
_________.

     The Disbursement Agent, the Trustee and the Issuer are entitled to rely on
the foregoing representations, warranties and certifications relative to
authorizing the Issuer to enter into the Construction Contract.

                                         PROFESSIONAL ASSOCIATES
                                         CONSTRUCTION SERVICES, INC.

                                         By:
                                            ------------------------------------
                                         Name:
                                         Title:

                                   Page 2 of 2
                             EXHIBIT 1 TO EXHIBIT K
<Page>

             EXHIBIT L TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
                             PERMITTED ENCUMBRANCES

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                             SCHEDULE B - SECTION 2

                                   EXCEPTIONS

Issuing Office File No.: 2003-10-01

ANY POLICY WE ISSUE WILL HAVE THE FOLLOWING EXCEPTIONS UNLESS THEY ARE TAKEN
CARE OF TO OUR SATISFACTION.

1  [Intentionally deleted]
2  [Intentionally deleted]
3  [Intentionally deleted]
4  [Intentionally deleted]
5  [Intentionally deleted]
6  [Intentionally deleted]
7  Any lease, grant, exception or reservation of minerals or mineral rights on,
   and under subject land.
8  Taxes and assessments for the year 2003, which are not yet due and payable.
9  Rights of way for highway or drainage purposes in favor of the State Highway
   Commission to be relocated to the 20 foot easement as shown on the survey of
   Grant Gilleon, P.L.S., resurveyed October 10, 2003, pursuant to the Drainage
   Easement and Relocation Agreement with Premier Entertainment Biloxi LLC,
   dated           , 2003, and recorded in Deed Book      at      Page    , but
   reserving the right to continue to use the following vacated rights of way
   on a temporary basis until the new easement improvements are constructed:
     a.   dated December 13, 1954, and recorded in Deed Book 390, Page 505 (Copy
          Book 139, Page 119) (PARCEL 4); and
     b.   dated February 4, 1955, and recorded in Deed Book 392, Page 319 (Copy
          Book 139, Page 559) (PARCEL 5).
10 Utility easements in favor of Mississippi Power Company as follows:
     a.   dated March 29, 1984, and recorded in Deed Book 144, Page 247 (PARCEL
          1);
     b.   dated _________, 2003, and recorded in Deed Book ____ at Page ________
          (PARCEL 2) as part of the Easement and Relocation Agreement with
          Premier Entertainment Biloxi LLC, which also includes the right to
          continue to use the electric distribution and communication facilities
          constructed pursuant to the now vacated Easement in favor of
          Mississippi Power Company dated March 27, 2001, and recorded in Deed
          Book 368, Page 608 (PARCEL 1) on a temporary basis until the earlier
          of (i) the date the new easement improvements are constructed or (ii)
          ________, 2003;
     c.   dated July 27, 1983, and recorded in Deed Book 135, Page 219 (PARCEL
          3);
     d.   dated May 31, 1983, and recorded in Deed Book 135, Page 226 (PARCEL
          4), which easement has been amended by Partial Release of Easement
          dated ___________, 2003, and recorded in Deed Book ____ at Page
          _________ to vacate the portion thereof running along the western
          boundary of PARCEL 4 only but preserve the easement along the northern
          boundary of said parcel;
     e.   dated July 20, 1983, and recorded in Deed Book 135, Page 222 (PARCEL
          5); and
     f.   dated May 25, 1983, and recorded in Deed Book 135, Page 224 (PARCEL
          6).

                                   Page 1 of 4
                                    EXHIBIT L
<Page>

   The utility easements described in Item 10.a., d., and f. above are subject
   to the terms and conditions of the Encroachment Agreement between
   Mississippi Power Company and Premier Entertainment Biloxi LLC dated
   ________ , 2003, and recorded in Deed Book ____ at Page _______.
11 Sewer easement as shown on Conditional Use Plat dated May 9, 1986, and filed
   in Plat Book 11, Page 19 (PARCEL 6).
12 Storm drain easement in favor of the City of Biloxi, Mississippi, to be
   relocated to the 20 foot easement as shown on the survey of Grant Gilleon,
   P.L.S., resurveyed October 10, 2003, pursuant to the Right of Entry and
   Relocation Agreement with Premier Entertainment Biloxi LLC, dated ______,
   2003, and recorded in Deed Book ______at Page ________, but reserving the
   right to use the vacated easement dated July 13, 1976, and recorded in Deed
   Book 77, Page 306, on a temporary basis until the earlier of (i) the date the
   new easement improvements are constructed or (ii) _________, 2003 (PARCEL 5).
13 Sewer easement in favor of the City of Biloxi, Mississippi, dated June 1,
   1983, and recorded in Deed Book 133, Page 228 (PARCEL 2).
14 [Intentionally deleted].
15 Easements or rights of way in favor of Mississippi Power Company for electric
   distribution lines; the City of Biloxi, Mississippi, for sewer lines; and the
   Mississippi State Highway Commission for highway or drainage purposes which
   are or may have been located in Magnolia Street if extended south of Highway
   90, which unopened street was vacated, subject to the preservation of such
   easements, by Final Decree in the matter of Leonard Darrell Chitty, et al v.
   Mississippi Power Company, et al, Cause No. 8612 in the Chancery Court of the
   Second Judicial District of Harrison County, Mississippi, dated March 6,
   1979, and recorded in Deed Book 92 at Page 373 (PARCEL 6).
16 General Covenant D prohibiting discrimination as set forth in that certain
   Warranty Deed from the City of Biloxi, Mississippi, and the Biloxi Port
   Commission to McWhorter and Johnson, Joint Venture (f/k/a Harbor View) dated
   December 29, 1981, and recorded in Deed Book 116, Page 500. (PARCEL 2).
17 Easement for maintenance of subsurface bulkhead tie-backs and General
   Covenant D prohibiting discrimination as set forth in that certain Warranty
   Deed from the City of Biloxi, Mississippi, and the Biloxi Port Commission to
   The Development Partnership, Ltd., and Mariner's Harbor Development dated
   April 30, 1982, and recorded in Deed Book 120, Page 1, as corrected by
   Corrected Special Warranty Deed recorded in Deed Book 136, Page 367 and 461.
   (PARCELS 1 AND L4).
18 Easement for vehicular and pedestrian ingress and egress across Parcels L1,
   L3, and L4 to the docking facility adjoining, the covenant requiring no less
   than 47 parking spaces on Parcels L1, L2, L3, and L4 for the benefit of the
   public using the adjoining docking facility, and the covenant restricting
   portions of Parcels L3 and L4 for use as a facility for docking by commercial
   fishing vessels and related activities as set forth in the following Deeds of
   Conveyance:
     a.   from the City of Biloxi, Mississippi, to the City of Biloxi,
          Mississippi, and the Biloxi Port Commission dated December 8, 1975,
          and recorded in Deed Book 62, Page 355, and corrected by instrument
          dated January 30, 1976, and recorded in Deed Book 63, Page 448; and
     b.   from the Biloxi Development Commission-Urban Renewal Agency of the
          City of Biloxi, Mississippi, to the City of Biloxi, Mississippi, and
          the Biloxi Port Commission dated December 11, 1975, and recorded in
          Deed Book 62, Page 383, and corrected by instruments dated January 6,
          1976, and recorded in Deed Book 63, Page 226, and dated January 19,
          1976, and recorded in Deed Book 63, Page 400.
   This policy affirmatively insures against loss resulting from a violation or
   alleged violation of said covenants, provided that upon completion of
   construction of the parking garage and elevated bridge on such parcels as
   contemplated by the Lease and Air Rights Agreement described in Item 21
   hereinbelow, such improvements are continuously available for public or
   harbor patron use free of charge. For purposes of this Item 18, reasonable
   restrictions on the access to and use of the parking

                                   Page 2 of 4
                                    EXHIBIT L
<Page>

   structure and the segregation of certain portions of the parking structure
   for valet and other similar purposes will be consistent with the provision of
   continuous access to the public or harbor patron free of charge, provided
   these restrictions on access, use and segregation for valet and similar
   purposes do not restrict the public from using any portion of the parking
   structure located on Parcels L3 and L4.
19 Covenant requiring the use of a 96' (foot) wide portion of PARCEL L3 "for
   public inner-harbor purposes" set forth in the conveyance from Mary C. Holmes
   to the Biloxi Yacht Club, dated March 16, 1943, and recorded in Deed Book
   254, at Page 249 and the related reversionary clause. This policy
   affirmatively insures against loss resulting from a violation or alleged
   violation of said covenant, provided that upon completion of construction of
   the parking garage on such parcel as contemplated by the Lease and Air Rights
   Agreement described in Item 21 hereinbelow, such improvements are
   continuously available for public or harbor patron use free of charge. For
   purposes of this Item 19, reasonable restrictions on the access to and use of
   the parking structure and the segregation of certain portions of the parking
   structure for valet and other similar purposes will be consistent with the
   provision of continuous access to the public or harbor patron free of charge
   provided these restrictions on access, use and segregation for valet and
   similar purposes do not restrict the public from using any portion of the
   parking structure located on Parcel L3
20 Terms and conditions of the Public Trust Tidelands Lease executed by the
   State of Mississippi and Premier Entertainment, LLC, succeeded in interest by
   merger with Premier Entertainment Biloxi LLC, dated ________ and recorded in
   Deed Book _____ at Page _______ and any failure to comply with same (PARCEL
   L9), and the lien against the adjacent uplands set forth in SECTION 26.5 of
   such lease (PARCELS 2, 3, 4, 5, and 6).
21 Terms and conditions of the Lease and Air Rights Agreement dated as of
   _____________,  2003,  and executed by the City of Biloxi, Mississippi, and
   Premier Entertainment Biloxi LLC and recorded in Deed Book _________ at Page
   ________ and any failure to comply with same (PARCELS L1, L2, L3, L4, and
   L6).
22 Concurrent rights of others to the use of the ground space and public
   roadways dedicated or to be dedicated on Parcels L1, L3, L4, and L6 and to
   the use of Parcel L2 by the public for parking prior to the commencement of
   construction as set forth in that certain Lease and Air Rights Agreement
   described in Item 21 hereinabove.
23 Public right of access to the open water portion of tidelands located on
   Parcel L9.
24 Pending disbursement of the full proceeds of the loan secured by the Deed of
   Trust insured, this policy insures only to the extent of the actual amount
   disbursed in good faith and without knowledge of any intervening lien or
   interest, but increases as each disbursement is made, up to the face amount
   of the policy. Such disbursement shall not extend the date of the policy or
   change any part thereof unless such change is specifically made by written
   endorsement duly issued on behalf of the Company. At the time of each
   disbursement of the proceeds of the loan and the issuance of endorsement, the
   title must be continued down to the date of endorsement for possible liens,
   including mechanics' liens and other objections intervening between the last
   preceding disbursement and such endorsement, and evidence of satisfaction and
   cancellation of same be furnished, together with the affidavit of owner and
   contractors as to any known liens. As of the date of the policy, the policy
   will insure the initial disbursement amount.
25 The following matters shown on the plat of survey of Grant H. Gilleon,
   P.L.S., dated August 21, 1998, and resurveyed April 23, 2003 and October 10,
   2003:
     Setback lines as indicated for all parcels pursuant to the variances
          obtained to the zoning ordinances of the City of Biloxi, Mississippi;
     b.   Fences, curbing and/or landscaping appurtenant to PARCEL 1 encroaching
          along the North boundary of said parcel onto Highway 90, along the
          West boundary of said parcel onto PARCEL L2, and on the Northwest
          corner of said parcel onto the ground space of PARCEL L1;
     c.   36" x 56" arch pipe crossing the east side of the ground space of
          PARCEL L3;

                                   Page 3 of 4
                                    EXHIBIT L
<Page>

     d.   Fences and curbing appurtenant to PARCEL 2 encroaching along the East
          boundary of said parcel onto the ground space of PARCEL L1
     e.   Fence running off the property line between PARCELS 2 and 3;
     f.   Telephone lines outside the utility easement on PARCEL 3 leading from
          the North boundary of said parcel onto PARCEL 2 and along the West
          boundary thereof;
     g.   Water lines and sewer force main running along the East boundary of
          PARCEL 3;
     h.   Water lines running along the North boundaries of PARCELS 2, 3, 4, 5,
          and 6;
     i.   Water lines running along the West boundary of PARCEL 5 and crossing
          said parcel near the South boundary, leading onto and across PARCELS
          4, 3, and 2;
     j.   Drainage pipe or culvert outside the drainage easement on PARCEL 5
          running across the Northeast corner of said parcel;
     k.   4" pipe from drainage manhole in Highway 90 right of way running onto
          PARCEL 6; and
     l.   Drain inlet crossing from PARCEL 5 onto PARCEL 6 in the Southwest
          corner of PARCEL 5.
     m.   Concrete sewer vault, water and sewer lines, drain inlet, and sewer
          manhole cover located on the ground space of PARCEL L1.
     n.   Electric meter and fuse box, sewer lift station, water valves, and
          water and sewer lines located on PARCEL L2
     o.   Concrete bulkhead, water meters, water valves, gas meter, and water
          and power lines located on the ground space of PARCEL L3.
     p.   Drain inlet, concrete bulkhead, grease trap, sewer manholes, sewer
          lines, and parking spaces located on PARCEL L6.
26 Documents related to the insured loan and to be recorded in the land records
   such as Assignment of Leases and Rents and UCC-1 Financing Statements as
   Fixture Filings, if any. Any such documents which are recorded subsequent to
   the insured Deed of Trust will be designated as subordinate liens on the
   lender's policy.
27 Terms and conditions of the Lease Agreement (Cafe) executed by Premier
   Entertainment Biloxi LLC in favor of Hard Rock Cafe International (STP),
   Inc., dated December 30, 2003, a memorandum of which is recorded in Deed Book
   _____ at Page __________ and any failure to comply with same, which lease has
   been subordinated to the insured deed of trust pursuant to the Subordination,
   Non-Disturbance and Attornment Agreement executed by Hard Rock Cafe
   International (STP), Inc., and the Insured dated ____________, 2004, and
   recorded in Deed of Trust Book ___ at Page __________. Such lease will be
   designated as a subordinate matter on the lender's policy.
28 Terms and conditions of the Lease Agreement (Retail Store) executed by
   Premier Entertainment Biloxi LLC in favor of Hard Rock Cafe International
   (STP), Inc., dated December 30, 2003, a memorandum of which is recorded in
   Deed Book ___at Page ________ and any failure to comply with same, which
   lease has been subordinated to the insured deed of trust pursuant to the
   Subordination, Non-Disturbance and Attornment Agreement executed by Hard Rock
   Cafe International (STP), Inc., and the Insured dated _________, 2004, and
   recorded in Deed of Trust Book ________ at _____ Page ____. Such lease will
   be designated as a subordinate matter on the lender's policy.

                                   Page 4 of 4
                                    EXHIBIT L
<Page>

            EXHIBIT M-1 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT
                             Affidavit and Agreement

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                             AFFIDAVIT AND AGREEMENT

STATE OF MISSISSIPPI                         Issuing Office File No.: 2003-10-01
COUNTY OF HARRISON

                                    (OWNERS)
                                    (INTERIM)

     PERSONALLY appeared before me, the undersigned authority in and for said
county and state, the duly authorized representative of the undersigned owner,
who after being first duly sworn states on oath:

     The undersigned is the owner in connection with the improvements on the
real property situated in the County of HARRISON, State of Mississippi known as:
PARCELS 1, 2, 3, 4, 5, 6, L1, L2, L3, L4, L6 AND L9, 2ND JUDICIAL DISTRICT,
HARRISON COUNTY, MISSISSIPPI, more particularly described in the Deed of Trust,
Mortgage or other Security Instrument in favor of U.S. BANK NATIONAL
ASSOCIATION, A NATIONAL BANKING ASSOCIATION, AS TRUSTEE ("TRUSTEE"), dated
_____________, securing the sum of $160,000,000.00 (that may be increased to
$190,000,000.00) and filed or to be filed for record in the office of the
recorder of the county in which the above land is located, which Deed of Trust,
Mortgage or other Security Instrument is a valid first lien on said premises to
the extent of all sums advanced to date; and,

     That no contracts have been let or guarantees of payment made by the
undersigned owner to anyone other than: (List each contract let or guarantee
made and obtain affidavit and agreement for each)

     ROY ANDERSON CORP AND ANY OTHER CONTRACTORS LISTED ON EXHIBIT "A" ATTACHED
     HERETO

     The owner has no interest or ownership in the contracting firm or firms and
the contractor has no interest in the real property described above, except:

     NONE; HOWEVER, IN THE INTEREST OF FULL DISCLOSURE, NOTE THAT ROY ANDERSON
     III IS BOTH A MEMBER OF A LIMITED LIABILITY COMPANY WHICH IS A MEMBER OF
     OWNER AS WELL AS AN OFFICER OF CONTRACTOR.

     The undersigned owner is in possession of the subject premises, unless
otherwise stated: (LIST POSSESSION OTHER THAN BY OWNER, SUCH AS LEASES, ETC.)

     NONE OTHER (i) THAN CONCURRENT RIGHTS OF THE CITY OF BILOXI TO PARCELS L1,
     L3, L4 AND L5 AND OF THE PUBLIC TO EXTENT A PUBLIC STREET HAS BEEN
     DEDICATED ON SUCH PARCELS, AND (ii) [IF HARD ROCK INTERNATIONAL (STP), INC.
     HAS TAKEN POSSESSION:] [____] IS IN POSSESSION OF THE LEASEHOLD ESTATE
     DESCRIBED IN THE LEASE AGREEMENT (CAFE) AND LEASE AGREEMENT (RETAIL STORE)
     [OR LIST OTHER TENANTS ON EXHIBIT "B" IF ANY HAVE TAKEN POSSESSION].

     The owner has paid in full any and all amounts due architects, engineers,
surveyors, attorneys, subcontractors, materialmen and laborers with whom it has
contracted directly or in its name through an agent for work or services
performed and materials furnished to date to the undersigned in connection with
the construction of the improvements on the above property, except: (IF NONE,
STATE "NONE")

     NONE OTHER THAN 1) RETAINAGE AMOUNTS IN THE AMOUNT OF $___________; 2)
     PUNCHLIST AMOUNTS IN THE AMOUNT OF $_______; 3) THE AMOUNTS OF $_________
     REQUESTED TO BE PAID TO [CONTRACTOR] IN THE

                                   Page 1 of 2
                                   EXHIBIT M-1
<Page>

     CURRENT MONTH'S DISBURSEMENT REQUEST; AND 4) $__________ REPRESENTING
     AMOUNTS IN DISPUTE UNDER THE [CONTRACT]. [ATTACHED SEPARATE EXHIBIT, IF
     NECESSARY]
                              (continued on Page 2)

     The owner has received no written notice of any unpaid bills or claims for
labor or services performed or materials on the above project, except: (IF NONE,
STATE "NONE")

     NONE

     The owner states that, except as permitted in that certain indenture dated
January 23, 2004 entered into with the Trustee, it has given or executed no
chattel mortgages, conditional sales contracts, security agreements, financing
statements, retention of title agreements, personal property leases or the like
and none are now outstanding as to any materials, fixtures, appliances,
furnishings or equipment placed upon, installed in or upon the aforesaid
premises or the improvements thereon.

     The owner hereby requests First American Title Insurance Company to issue
its policy or policies of title insurance, or endorsements thereto, upon said
real estate without exception therein as to any possible unfiled mechanics' or
materialmen's lien, and in consideration thereof, and as an inducement therefor,
the undersigned does hereby agree to indemnify and hold harmless the said First
American Title Insurance Company of and from any and all loss, cost, damage and
expense of every kind including attorney's fees, which said First American Title
Insurance Company shall suffer or may suffer or incur or become liable for under
its said policy or policies now to be issued or any reissue, renewal or
extension thereof, or a new policy anytime issued upon said real estate, part
thereof or interest therein arising, directly or indirectly, out of or on
account of any such mechanics' or materialmen's liens, claim or claims as a
result of the undersigned's unpaid bills or in connection with its enforcement
of its rights under this agreement.

                                         OWNER:

                                         PREMIER ENTERTAINMENT BILOXI LLC,
                                         A Delaware limited liability company

                                         By:
                                              ----------------------------------
                                              Its Manager

                                         By:
                                            ------------------------------------
                                         Its:
                                             -----------------------------------

STATE OF_________________
COUNTY OF________________

SWORN TO AND SUBSCRIBED before me, by the duly authorized member of Manager and
Owner on behalf of both Manager and Owner, whose signature appears above, this
the ________________ day of _________________, 200__.

                                         -----------------------------------
                                         NOTARY PUBLIC

My Commission Expires:
                      -----------------

                                   Page 2 of 2
                                   EXHIBIT M-1
<Page>

           EXHIBIT M-2 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                             AFFIDAVIT AND AGREEMENT

STATE OF MISSISSIPPI                         Issuing Office File No.: 2003-10-01
COUNTY OF HARRISON

                              (GENERAL CONTRACTORS)
                                    (INTERIM)

     PERSONALLY appeared before me, the undersigned authority in and for said
county and state, the duly authorized representative of the general contractor,
who after being first duly sworn states on oath:

     The undersigned is the general contractor in connection with improvements
on the real property situated in the County of HARRISON, State of Mississippi
known as: PARCELS 1, 2, 3, 4, 5, 6, L1, L2, L3, L4, L6 AND L9, 2ND JUDICIAL
DISTRICT, HARRISON COUNTY, MISSISSIPPI, more particularly described in the Deed
of Trust, Mortgage or other Security Instrument in favor of U.S. BANK NATIONAL
ASSOCIATION, A NATIONAL BANKING ASSOCIATION, AS TRUSTEE, dated ___________,
securing the sum of $160,000,000 (that may be increased to $190,000,000.00), and
filed or to be filed for record in the office of the recorder of the county in
which the above land is located, which Deed of Trust, Mortgage or other Security
Instrument is a valid first lien on said premises to the extent of all sums
advanced to date; and,

     The general contractor has been paid in full all sums due for work or
services performed and materials furnished on the above project and does hereby
waive, release and surrender any and all liens to the date for which payment is
made, for labor, services, and/or materials furnished by the undersigned upon
the premises described above, except:(IF NONE, STATE "NONE")

     NONE OTHER THAN 1) RETAINAGE AMOUNTS IN THE AMOUNT OF $___________; 2)
     PUNCHLIST AMOUNTS IN THE AMOUNT OF $_______; 3) THE AMOUNTS OF $_________
     REQUESTED TO BE PAID TO [CONTRACTOR] IN THE CURRENT MONTH'S DISBURSEMENT
     REQUEST; AND 4) $__________ REPRESENTING AMOUNTS IN DISPUTE UNDER THE
     [CONTRACT]. [ATTACH SEPARATE EXHIBIT, IF NECESSARY.]

     The general contractor has paid in full any and all amounts due architects,
engineers, surveyors, attorneys, subcontractors, materialmen and laborers for
work or services performed and materials furnished to date to the undersigned in
connection with the construction of the improvements on the above property,
except: (IF NONE, STATE "NONE")

     NONE OTHER THAN:
     1) RETAINAGE AMOUNTS IN THE AMOUNT OF $___________; 2) PUNCHLIST AMOUNTS IN
     THE AMOUNT OF $________; 3) THE AMOUNTS OF $_________ REQUESTED TO BE PAID
     TO [CONTRACTOR] IN THE CURRENT MONTH'S DISBURSEMENT REQUEST; AND 4)
     $__________ REPRESENTING AMOUNTS IN DISPUTE UNDER THE [CONTRACT]. [ATTACH
     SEPARATE EXHIBIT, IF NECESSARY.]

                              (continued on Page 2)

                                   Page 1 of 2
                                   EXHIBIT M-2
<Page>

     The general contractor states that it has given or executed no chattel
mortgages, conditional sales contracts, security agreements, financing
statements, retention of title agreements, personal property leases or the like
and none are now outstanding as to any materials, fixtures, appliances,
furnishings or equipment placed upon, installed in or upon the aforesaid
premises or the improvements thereon, and that to the extent that general
contractor has contracted for plumbing, heating, lighting, refrigerating and
other equipment and delivery of same has been made to general contractor or the
property, payment for such equipment has been made in full and,

     The general contractor hereby request(s) First American Title Insurance
Company to issue its policy or policies of title insurance, or endorsements
thereto, upon said real estate without exception therein as to any possible
unfiled mechanics' or materialmen's lien as to general contractor, its
subcontractors and suppliers, and in consideration thereof, and as an inducement
therefor, the undersigned does hereby agree to indemnify and hold harmless the
said First American Title Insurance Company of and from any and all loss, cost,
damage and expense of every kind including attorney's fees, which said First
American Title Insurance Company shall suffer or may suffer or incur or become
liable for under its said policy or policies now to be issued or any reissue,
renewal or extension thereof, or a new policy anytime issued upon said real
estate, part thereof or interest therein arising, directly or indirectly, out of
or on account of any such mechanics' or materialmen's liens, claim or claims as
a result of the undersigned's unpaid bills or in connection with its enforcement
of its rights under this agreement.

                                         GENERAL CONTRACTOR:

                                         ROY ANDERSON CORP

                                         By:
                                            ---------------------------------
                                                 Its:
                                                     ------------------------

STATE OF_________________
COUNTY OF________________

SWORN TO AND SUBSCRIBED before me, by ____________________________, the duly
authorized representative of the Contractor whose signature appears above, this
the ________________ day of ___________________________, 200__.

                                         ---------------------------------
                                         NOTARY PUBLIC

My Commission Expires:
                      --------------------

                                   Page 2 of 2
                                   EXHIBIT M-2
<Page>

            EXHIBIT M-3 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                             AFFIDAVIT AND AGREEMENT

STATE OF MISSISSIPPI                         Issuing Office File No.: 2003-10-01
COUNTY OF HARRISON

                                  (CONTRACTORS)
                                    (INTERIM)

     PERSONALLY appeared before me, the undersigned authority in and for said
county and state, the duly authorized representative of the undersigned
contractor, who after being first duly sworn states on oath:

     The undersigned is a contractor with Premier Entertainment Biloxi LLC in
connection with improvements on the real property situated in the County of
HARRISON, State of Mississippi known as: PARCELS 1, 2, 3, 4, 5, 6, L1, L2, L3,
L4, L6 AND L9, 2ND JUDICIAL DISTRICT, HARRISON COUNTY, MISSISSIPPI, more
particularly described in the Deed of Trust, Mortgage or other Security
Instrument in favor of U.S. BANK NATIONAL ASSOCIATION, A NATIONAL BANKING
ASSOCIATION, AS TRUSTEE, dated ________________, securing the sum of
$160,000,000 (that may be increased to $190,000,000.00), and filed or to be
filed for record in the office of the recorder of the county in which the above
land is located, which Deed of Trust, Mortgage or other Security Instrument is a
valid first lien on said premises to the extent of all sums advanced to date;
and,

     The contractor has been paid in full all sums due for work or services
performed and materials furnished on the above project and does hereby waive,
release and surrender any and all liens to the date for which payment is made,
for labor, services, and/or materials furnished by the undersigned upon the
premises described above, except:(IF NONE, STATE "NONE")

     NONE OTHER THAN 1) RETAINAGE AMOUNTS IN THE AMOUNT OF $___________; 2)
     PUNCHLIST AMOUNTS IN THE AMOUNT OF $__________; 3) THE AMOUNTS OF
     $_________ REQUESTED TO BE PAID TO [CONTRACTOR] IN THE CURRENT MONTH'S
     DISBURSEMENT REQUEST; AND 4) $__________ REPRESENTING AMOUNTS IN DISPUTE
     UNDER THE [CONTRACT]. [ATTACHED SEPARATE EXHIBIT, IF NECESSARY.

     The contractor has paid in full any and all amounts due subcontractors,
materialmen and laborers for work or services performed and materials furnished
to date to the undersigned in connection with the construction of the
improvements on the above property, except: (IF NONE, STATE "NONE")

     NONE OTHER THAN 1) RETAINAGE AMOUNTS IN THE AMOUNT OF $___________; 2)
     PUNCHLIST AMOUNTS IN THE AMOUNT OF $__________; 3) THE AMOUNTS OF
     $_________ REQUESTED TO BE PAID TO [CONTRACTOR] IN THE CURRENT MONTH'S
     DISBURSEMENT REQUEST; AND 4) $__________ REPRESENTING AMOUNTS IN DISPUTE
     UNDER THE [CONTRACT]. [ATTACHED SEPARATE EXHIBIT, IF NECESSARY.

                              (continued on Page 2)

                                   Page 1 of 2
                                   EXHIBIT M-3
<Page>

     The contractor states that no chattel mortgages, conditional sales
contracts, security agreements, financing statements, retention of title
agreements, personal property leases or the like have been given or are now
outstanding as to any materials, fixtures, appliances, furnishings or equipment
contractor placed upon, installed in or upon the aforesaid premises or the
improvements thereon, and that all such equipment is fully paid for and,

     The contractor hereby request(s) First American Title Insurance Company to
issue its policy or policies of title insurance, or endorsements thereto, upon
said real estate without exception therein as to any possible unfiled mechanics'
or materialmen's lien as to the contractor, its subcontractors and suppliers,
and in consideration thereof, and as an inducement therefor, the undersigned
does hereby agree to indemnify and hold harmless the said First American Title
Insurance Company of and from any and all loss, cost, damage and expense of
every kind including attorney's fees, which said First American Title Insurance
Company shall suffer or may suffer or incur or become liable for under its said
policy or policies now to be issued or any reissue, renewal or extension
thereof, or a new policy anytime issued upon said real estate, part thereof or
interest therein arising, directly or indirectly, out of or on account of any
such mechanics' or materialmen's liens, claim or claims as a result of the
undersigned's unpaid bills or in connection with its enforcement of its rights
under this agreement.

                                         CONTRACTOR:

                                         ---------------------------------------

                                         By:
                                            ------------------------------------
                                               Its:
                                                   -----------------------------

STATE OF______________
COUNTY OF_____________

SWORN TO AND SUBSCRIBED before me, by _______________________, the duly
authorized representative of the Contractor whose signature appears above, this
the __________ day of _________________________, 200__.

                                         -----------------------------------
                                         NOTARY PUBLIC

My Commission Expires:
                       -------------------------

                                   Page 2 of 2
                                   EXHIBIT M-3
<Page>

            EXHIBIT M-4 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT

                      FORM OF FINAL LIEN AFFIDAVIT (OWNER)

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                             AFFIDAVIT AND AGREEMENT

STATE OF MISSISSIPPI                         Issuing Office File No.: 2003-10-01
COUNTY OF HARRISON

                                (OWNER'S - FINAL)

     PERSONALLY appeared before me, the undersigned authority in and for said
county and state, the duly authorized representative of the undersigned owner,
who after being first duly sworn states on oath:

     The undersigned is the owner in connection with the improvements on the
real property situated in the County of HARRISON, State of Mississippi known as:
PARCELS 1, 2, 3, 4, 5, 6, L1, L2, L3, L4, L6 AND L9, BILOXI SECTION BLOCKS 100,
130, AND 130.5, 2ND JUDICIAL DISTRICT, HARRISON COUNTY, MISSISSIPPI, more
particularly described in the Deed of Trust, Mortgage or other Security
Instrument in favor of U.S. BANK NATIONAL ASSOCIATION, A NATIONAL BANKING
ASSOCIATION, AS TRUSTEE ("TRUSTEE"), dated__________ , 2004, securing the sum of
$160,000,000 (that may be increased to $190,000,000.00) and filed or to be filed
for record in the office of the recorder of the county in which the above land
is located, which Deed of Trust, Mortgage or other Security Instrument is a
valid first lien on said premises; and,

     That no contracts have been let or guarantees of payment made by the
undersigned owner to anyone other than: (List each contract let or guarantee
made and obtain affidavit and agreement for each)

     ROY ANDERSON CORP AND ANY OTHER CONTRACTORS LISTED ON EXHIBIT "A" ATTACHED
     HERETO

     The owner has no interest or ownership in the contracting firm or firms and
the contractor has no interest in the real property described above, except:

     NONE; HOWEVER, IN THE INTEREST OF FULL DISCLOSURE, NOTE THAT ROY ANDERSON
     III IS BOTH A MEMBER OF A LIMITED LIABILITY COMPANY WHICH IS A MEMBER OF
     OWNER AS WELL AS AN OFFICER OF CONTRACTOR.

     The undersigned owner is in possession of the subject premises, unless
otherwise stated: (LIST POSSESSION OTHER THAN BY OWNER, SUCH AS LEASES, ETC.).

     NONE OTHER (I) THAN CONCURRENT RIGHTS OF THE CITY OF BILOXI TO PARCELS L1,
     L3, L4 AND L5 AND OF THE PUBLIC TO EXTENT A PUBLIC STREET HAS BEEN
     DEDICATED ON SUCH PARCELS, AND (II) [IF HARD ROCK INTERNATIONAL (STP), INC.
     HAS TAKEN POSSESSION:] [____] IS IN POSSESSION OF THE LEASEHOLD ESTATE
     DESCRIBED IN THE LEASE AGREEMENT (CAFE) AND LEASE AGREEMENT (RETAIL STORE)
     [OR LIST OTHER TENANTS ON EXHIBIT "B" IF ANY HAVE TAKEN POSSESSION].

     The owner has paid in full any and all amounts due architects, engineers,
surveyors, attorneys, subcontractors, materialmen and laborers with whom it has
contracted directly or in its name through an agent for work or services
performed and materials furnished to the undersigned in connection with the
construction of the improvements on the above property, except: (IF NONE, STATE
"NONE")

     NONE OTHER THAN THE AMOUNTS OF $_________ REQUESTED TO BE PAID TO
     [CONTRACTOR] IN THE FINAL DISBURSEMENT REQUEST.

                                   Page 1 of 2
                                   EXHIBIT M-4
<Page>

                              (continued on Page 2)

     The owner has received no written notice of any unpaid bills or claims for
labor or services performed or materials on the above project, except: (IF NONE,
STATE "NONE")

     NONE

     The owner states that, except as permitted in that certain indenture dated
January 23, 2004 entered into with the Trustee, it has given or executed no
chattel mortgages, conditional sales contracts, security agreements, financing
statements, retention of title agreements, personal property leases or the like
and none are now outstanding as to any materials, fixtures, appliances,
furnishings or equipment placed upon, installed in or upon the aforesaid
premises or the improvements thereon, and that to the extent that owner has
contracted directly or in its name through an agent for plumbing, heating,
lighting, refrigerating and other equipment and delivery of same has been made
to owner or the property, payment for such equipment has been made in full and,

     The owner hereby requests First American Title Insurance Company to issue
its policy or policies of title insurance, or endorsements thereto, upon said
real estate without exception therein as to any possible unfiled mechanics' or
materialmen's lien, and in consideration thereof, and as an inducement therefor,
the undersigned does hereby agree to indemnify and hold harmless the said First
American Title Insurance Company of and from any and all loss, cost, damage and
expense of every kind including attorney's fees, which said First American Title
Insurance Company shall suffer or may suffer or incur or become liable for under
its said policy or policies now to be issued or any reissue, renewal or
extension thereof, or a new policy anytime issued upon said real estate, part
thereof or interest therein arising, directly or indirectly, out of or on
account of any such mechanics' or materialmen's liens, claim or claims as a
result of the undersigned's unpaid bills or in connection with its enforcement
of its rights under this agreement.

                               OWNER:

                               PREMIER ENTERTAINMENT BILOXI LLC,
                               A Delaware limited liability company

                               By:    GAR, LLC, a Mississippi limited liability
                                      company
                                      Its Manager

                               By:
                                  ----------------------------------------------
                                      Its:
                                          --------------------------------------

STATE OF_______________
COUNTY OF______________

SWORN TO AND SUBSCRIBED before me, by the duly authorized member of Manager and
Owner on behalf of both Manager and Owner, whose signature appears above, this
the_________ day of_____________ , 200___.

                             --------------------------------------
                             NOTARY PUBLIC

My Commission Expires:
                      ------------------

                                   Page 2 of 2
                                   EXHIBIT M-4
<Page>

            EXHIBIT M-5 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT

                FORM OF FINAL LIEN AFFIDAVIT (GENERAL CONTRACTOR)

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                             AFFIDAVIT AND AGREEMENT

STATE OF MISSISSIPPI                         Issuing Office File No.: 2003-10-01
COUNTY OF HARRISON

                         (GENERAL CONTRACTOR'S - FINAL)

     PERSONALLY appeared before me, the undersigned authority in and for said
county and state, the duly authorized representative of the general contractor,
who after being first duly sworn states on oath:

     The undersigned is the general contractor in connection with improvements
on the real property situated in the County of HARRISON, State of Mississippi
known as: PARCELS 1, 2, 3, 4, 5, 6, L1, L2, L3, L4, L6 AND L9, BILOXI SECTION
BLOCKS 100, 130, AND 130.5, 2ND JUDICIAL DISTRICT, HARRISON COUNTY, MISSISSIPPI,
more particularly described in the Deed of Trust, Mortgage or other Security
Instrument in favor of U.S. BANK NATIONAL ASSOCIATION, A NATIONAL BANKING
ASSOCIATION, AS TRUSTEE, dated________, 2004, securing the sum of $$160,000,000
(that may be increased to $190,000,000.00), and filed or to be filed for record
in the office of the recorder of the county in which the above land is located,
which Deed of Trust, Mortgage or other Security Instrument is a valid first lien
on said premises; and,

     The general contractor has been paid in full all sums due for work or
services performed and materials furnished on the above project and does hereby
waive, release and surrender any and all liens or claims or rights to liens to
the date for which payment is made, for labor, services, and/or materials
furnished by the undersigned upon the premises described above, except:(IF NONE,
STATE "NONE")

     NONE OTHER THAN 1) THE AMOUNTS OF $_________ REQUESTED TO BE PAID TO
     [CONTRACTOR] IN THE FINAL DISBURSEMENT REQUEST.

     The general contractor has paid in full any and all amounts due architects,
engineers, surveyors, attorneys, subcontractors, materialmen and laborers for
work or services performed and materials furnished to the undersigned in
connection with the construction of the improvements on the above property,
except: (IF NONE, STATE "NONE")

     NONE OTHER THAN THE AMOUNTS OF $_________ REQUESTED TO BE PAID TO
     [CONTRACTOR] IN THE FINAL DISBURSEMENT REQUEST.

                              (continued on Page 2)

                                   Page 1 of 2
                                   EXHIBIT M-5
<Page>

     The general contractor states that it has given or executed no chattel
mortgages, conditional sales contracts, security agreements, financing
statements, retention of title agreements, personal property leases or the like
and none are now outstanding as to any materials, fixtures, appliances,
furnishings or equipment placed upon, installed in or upon the aforesaid
premises or the improvements thereon, and that to the extent that general
contractor has contracted for plumbing, heating, lighting, refrigerating and
other equipment and delivery of same has been made to general contractor or the
property, payment for such equipment has been made in full and,

     The general contractor hereby request(s) First American Title Insurance
Company to issue its policy or policies of title insurance, or endorsements
thereto, upon said real estate without exception therein as to any possible
unfiled mechanics' or materialmen's lien as to general contractor, its
subcontractors and suppliers, and in consideration thereof, and as an inducement
therefor, the undersigned does hereby agree to indemnify and hold harmless the
said First American Title Insurance Company of and from any and all loss, cost,
damage and expense of every kind including attorney's fees, which said First
American Title Insurance Company shall suffer or may suffer or incur or become
liable for under its said policy or policies now to be issued or any reissue,
renewal or extension thereof, or a new policy anytime issued upon said real
estate, part thereof or interest therein arising, directly or indirectly, out of
or on account of any such mechanics' or materialmen's liens, claim or claims as
a result of the undersigned's unpaid bills or in connection with its enforcement
of its rights under this agreement.

                                          GENERAL CONTRACTOR:

                                          ROY ANDERSON CORP

                                          By:
                                             --------------------------------
                                                Its:
                                                    -------------------------

STATE OF______________
COUNTY OF_____________

SWORN TO AND SUBSCRIBED before me, by_______________ , the duly authorized
representative of the Contractor whose signature appears above, this the day
of______________, 200___.

                                          ------------------------------
                                          NOTARY PUBLIC
My Commission Expires:
                      -------------------

                                   Page 2 of 2
                                   EXHIBIT M-5
<Page>

            EXHIBIT M-6 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT

                FORM OF FINAL LIEN AFFIDAVIT (OTHER CONTRACTORS)

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                             AFFIDAVIT AND AGREEMENT

STATE OF MISSISSIPPI                         Issuing Office File No.: 2003-10-01
COUNTY OF HARRISON

                             (CONTRACTOR'S - FINAL)

     PERSONALLY appeared before me, the undersigned authority in and for said
county and state, the duly authorized representative of the undersigned
contractor, who after being first duly sworn states on oath:

     The undersigned contractor has a contract with Premier Entertainment Biloxi
LLC in connection with improvements on the real property situated in the County
of HARRISON, State of Mississippi known as: PARCELS 1, 2, 3, 4, 5, 6, L1, L2,
L3, L4, L6 AND L9, BILOXI SECTION BLOCKS 100, 130, AND 130.5, 2ND JUDICIAL
DISTRICT, HARRISON COUNTY, MISSISSIPPI, more particularly described in the Deed
of Trust, Mortgage or other Security Instrument in favor of U.S. BANK NATIONAL
ASSOCIATION, A NATIONAL BANKING ASSOCIATION, AS TRUSTEE, dated___________, 2004,
securing the sum of $$160,000,000 (that may be increased to $190,000,000.00),
and filed or to be filed for record in the office of the recorder of the county
in which the above land is located, which Deed of Trust, Mortgage or other
Security Instrument is a valid first lien on said premises; and,

     The contractor has been paid in full all sums due for work or services
performed and materials furnished on the above project and does hereby waive,
release and surrender any and all liens or claims or rights to liens to the date
for which payment is made, for labor, services, and/or materials furnished by
the undersigned upon the premises described above, except:(IF NONE, STATE
"NONE")

     NONE OTHER THAN 1) THE AMOUNTS OF $_________ REQUESTED TO BE PAID TO
     [CONTRACTOR] IN THE FINAL DISBURSEMENT REQUEST.

     The contractor has paid in full any and all amounts due subcontractors,
materialmen and laborers for work or services performed and materials furnished
to the undersigned in connection with the construction of the improvements on
the above property, except: (IF NONE, STATE "NONE")

     NONE OTHER THAN 1) THE AMOUNTS OF $_________ REQUESTED TO BE PAID TO
     [CONTRACTOR] IN THE FINAL DISBURSEMENT REQUEST.

                              (continued on Page 2)

                                   Page 1 of 2
                                   EXHIBIT M-6
<Page>

     The contractor states that no chattel mortgages, conditional sales
contracts, security agreements, financing statements, retention of title
agreements, personal property leases or the like have been given or are now
outstanding as to any materials, fixtures, appliances, furnishings or equipment
contractor placed upon, installed in or upon the aforesaid premises or the
improvements thereon, and that all such equipment is fully paid for and,

     The contractor hereby request(s) First American Title Insurance Company to
issue its policy or policies of title insurance, or endorsements thereto, upon
said real estate without exception therein as to any possible unfiled mechanics'
or materialmen's lien as to the contractor, its subcontractors and suppliers,
and in consideration thereof, and as an inducement therefor, the undersigned
does hereby agree to indemnify and hold harmless the said First American Title
Insurance Company of and from any and all loss, cost, damage and expense of
every kind including attorney's fees, which said First American Title Insurance
Company shall suffer or may suffer or incur or become liable for under its said
policy or policies now to be issued or any reissue, renewal or extension
thereof, or a new policy anytime issued upon said real estate, part thereof or
interest therein arising, directly or indirectly, out of or on account of any
such mechanics' or materialmen's liens, claim or claims as a result of the
undersigned's unpaid bills or in connection with its enforcement of its rights
under this agreement.

                                                CONTRACTOR:

                                                --------------------------------
                                                By:
                                                   -----------------------------
                                                     Its:
                                                         -----------------------

STATE OF______________
COUNTY OF_____________

SWORN TO AND SUBSCRIBED before me, by__________________, the duly authorized
representative of the Contractor whose signature appears above, this the
__________day of__________, 200_____.

                                          ------------------------
                                          NOTARY PUBLIC
My Commission Expires:
                      -------------------

                                   Page 2 of 2
                                   EXHIBIT M-6
<Page>

                                   EXHIBIT N-1

                 FORM OF COMMITMENT TO ISSUE UPDATE ENDORSEMENT

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                                   SCHEDULE A

Issuing Office File No.: 2003-10-01E

  THIS IS A COMMITMENT TO ISSUE ENDORSEMENT FURNISHED TO OR ON BEHALF OF THE
PARTY TO BE INSURED.
  THERE ARE ADDITIONAL REQUIREMENTS SET FORTH IN SECTION 1 OF SCHEDULE B
ATTACHED HERETO WHICH MUST BE MET BEFORE THE ENDORSEMENT CAN BE ISSUED IN THE
SAME FORM AS THIS COMMITMENT. THESE ADDITIONAL REQUIREMENTS INCLUDE THE
REQUIREMENT IN CLAUSE 2 OF SECTION 1 OF SCHEDULE B THAT THE DISBURSEMENT AGENT
NOTIFY THE ISSUING AGENT OF THE COMPANY, BALCH AND BINGHAM, LLP, BY TELEPHONE OR
EMAIL ON THE DISBURSEMENT DATE PRIOR TO MAKING SUCH DISBURSEMENT (THE
"CONFIRMATION NOTICE"). THIS SIGNED COMMITMENT MAY BE RESCINDED BY THE ISSUING
AGENT ON BEHALF OF THE COMPANY DURING THE CONFIRMATION NOTICE ONLY AS A RESULT
OF ANY LIEN OR OTHER OBJECTION TO TITLE INTERVENING BETWEEN THE LAST PRECEDING
DISBURSEMENT AND SUCH CONFIRMATION NOTICE WHERE EVIDENCE OF SATISFACTION AND
CANCELLATION OF SAME HAS NOT BEEN FURNISHED TO THE COMPANY.

1. Commitment Date:  [TBD IN CONJUNCTION WITH CONSTRUCTION DISBURSEMENT REQUEST]

2. Endorsement to be issued:

/X/  Construction Draw Endorsement to Loan Policy No. FA - [TBD WHEN ISSUED
     PURSUANT TO COMMITMENT NO. 2003-10-01]

     Endorsement Amount: $[TBD BY AUTHORIZED DISBURSEMENT REQUEST]

     Proposed Insured: U.S. BANK NATIONAL ASSOCIATION, A NATIONAL BANKING
ASSOCIATION, AS TRUSTEE UNDER THE INDENTURE DATED JANUARY 23, 2004, ITS
SUCCESSORS AND/OR ASSIGNS AS THEIR INTEREST MAY APPEAR

3. The property interests specified in the land insured hereby is vested in
PREMIER ENTERTAINMENT BILOXI LLC, A DELAWARE LIMITED LIABILITY COMPANY,
SUCCESSOR IN INTEREST BY MERGER WITH PREMIER ENTERTAINMENT, LLC, A MISSISSIPPI
LIMITED LIABILITY COMPANY, as follows:
FEE SIMPLE TITLE - PARCELS 1, 2, 3, 4, 5, AND 6
LEASEHOLD INTEREST - PARCELS L2 AND L9
     LEASEHOLD INTEREST IN AIR SPACE WITH GROUND SUPPORT STRUCTURES AND
NON-EXCLUSIVE EASEMENT
          - PARCELS L1, L3 AND L4
NON-EXCLUSIVE EASEMENT - PARCEL L6
4. The land referred to in this Commitment is described as follows:

                                  Page 1 of 16
                                   EXHIBIT N-1
<Page>

     SEE ATTACHED EXHIBIT "A" FOR LEGAL DESCRIPTION
     NOTE THE TYPE OF PROPERTY INTEREST TO BE INSURED AS INDICATED FOR EACH
PARCEL.

Issue Date:                                 BALCH & BINGHAM LLP, Issuing Agent
           ------------------------
                                            By:
                                               ---------------------------
                                               Authorized Signatory

                                  Page 2 of 16
                                   EXHIBIT N-1
<Page>
                     FIRST AMERICAN TITLE INSURANCE COMPANY

                                    EXHIBIT A

Issuing Office File No.: 2003-10-01E

                               LEGAL DESCRIPTION:

                                    PARCEL 1
                               FEE SIMPLE INTEREST

BEGIN at the northwest corner of Mariner's Harbor Condominiums, Biloxi, Harrison
County 2nd Judicial District, Mississippi as per the map or plat thereof on file
in the office of the Chancery Clerk at the Court House in Biloxi, Harrison
County 2nd Judicial District, Mississippi and run Easterly along the south right
of way line of West Beach Boulevard and along a curve to the left (having a
radius of 2323.00 feet, an internal angle of 9 degrees 20 minutes 27 seconds and
subtended by a chord of 378.30 feet along a bearing of South 88 degrees 53
minutes 47 seconds East) for 378.72 feet; thence run South 00 degrees 34 minutes
42 seconds East for 25.84 feet; thence run North 89 degrees 25 minutes 18
seconds East for 16.00 feet; thence run South 00 degrees 42 minutes 33 seconds
East for 143.27 feet; thence run West for 394.64 feet; thence run North 00
degrees 31 minutes 32 seconds West for 176.25 feet; back to the POINT OF
BEGINNING.

Said parcel of land is part of Biloxi Section Block 100.

                                  Page 3 of 16
                                   EXHIBIT N-1
<Page>

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                              EXHIBIT A (CONTINUED)

Issuing Office File No.: 2003-10-01E

                               LEGAL DESCRIPTION:
                                    PARCEL 2
                               FEE SIMPLE INTEREST

BEGIN at the northeast corner of Harbor View Condominiums, Biloxi, Harrison
County 2nd Judicial District, Mississippi as per the map or plat thereof on file
in the office of the Chancery Clerk at the Court House in Biloxi, Harrison
County 2nd Judicial District and run South 00 degrees 31 minutes 32 seconds East
for 239.05 feet; thence run North 89 degrees 28 minutes 33 seconds East for 3.66
feet; thence run South 00 degrees 23 minutes 59 seconds East for 124.18 feet;
thence run South 83 degrees 11 minutes 02 seconds East for 1.20 feet; thence run
South 01 degree 44 minutes 55 seconds East for 16.59 feet; thence run South 89
degrees 00 minutes 06 seconds West for 101.78 feet; thence run North 07 degrees
17 minutes 25 seconds West for 5.98 feet; thence run North 00 degrees 32 minutes
09 seconds West for 387.04 feet to the south right of way line of West Beach
Boulevard; thence run South 83 degrees 25 minutes 27 seconds East along said
right of way line for 98.37 feet back to the POINT OF BEGINNING.

Said parcel of land is a part of Biloxi Section Block 130.5, Biloxi, Harrison
County 2nd Judicial District, Mississippi.

                                  Page 4 of 16
                                   EXHIBIT N-1
<Page>

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                              EXHIBIT A (CONTINUED)

Issuing Office File No.: 2003-10-01E

                               LEGAL DESCRIPTION:
                                    PARCEL 3
                               FEE SIMPLE INTEREST

COMMENCE at the northeast corner of Harbor View Condominiums, Biloxi, Harrison
County 2nd Judicial District, Mississippi as per the map or plat thereof on file
in the office of the Chancery Clerk at the Court House in Biloxi, Harrison
County 2nd Judicial District and run North 83 degrees 25 minutes 27 seconds West
along the south right of way line of U.S. Highway 90 (Beach Boulevard) for 98.37
feet to and for the POINT OF BEGINNING.

From said POINT OF BEGINNING, run South 00 degrees 32 minutes 09 seconds East
for 387.04 feet; thence run North 49 degrees 17 minutes 42 seconds West for 9.81
feet; thence run South 89 degrees 20 minutes 48 seconds West for 92.63 feet;
thence run North 00 degrees 32 minutes 09 seconds West for 395.33 feet to the
south right of way line of U.S. Highway 90 (Beach Boulevard); thence run South
82 degrees 14 minutes 40 seconds East along said right of way line for 101.07
feet back to the POINT OF BEGINNING.

Said parcel of land is a part of Biloxi Section Block 130.5, Biloxi, Harrison
County 2nd Judicial District, Mississippi

                                  Page 5 of 16
                                   EXHIBIT N-1
<Page>

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                              EXHIBIT A (CONTINUED)

Issuing Office File No.: 2003-10-01E

                               LEGAL DESCRIPTION:
                                    PARCEL 4
                               FEE SIMPLE INTEREST

COMMENCE at the northeast corner of Harbor View Condominiums, Biloxi, Harrison
County 2nd Judicial District, Mississippi as per the map or plat thereof on file
in the office of the Chancery Clerk at the Court House in Biloxi, Harrison
County 2nd Judicial District and run North 83 degrees 25 minutes 27 seconds West
along the south right of way line of U.S. Highway 90 (Beach Boulevard) for 98.37
feet; thence run North 82 degrees 14 minutes 40 seconds West along said south
right of way line for 101.07 feet to and for the POINT OF BEGINNING.

From said POINT OF BEGINNING, run South 00 degrees 32 minutes 09 seconds East
for 395.33 feet; thence run South 89 degrees 20 minutes 48 seconds West for
107.38 feet; thence run North 00 degrees 42 minutes 02 seconds West for 415.84
feet to the south right of way line of U.S. Highway 90 (Beach Boulevard); thence
run South 79 degrees 57 minutes 09 seconds East along said right of way line for
110.45 feet back to the POINT OF BEGINNING.

Said parcel of land is a part of Biloxi Section Block 130.5, Biloxi, Harrison
County 2nd Judicial District, Mississippi.

                                  Page 6 of 16
                                   EXHIBIT N-1
<Page>

                         FIRST AMERICAN TITLE INSURANCE

                              EXHIBIT A (CONTINUED)

Issuing Office File No.: 2003-10-01E

                               LEGAL DESCRIPTION:
                                    PARCEL 5
                               FEE SIMPLE INTEREST

COMMENCE at an iron rod at the northeast corner of Harbor View Condominiums,
Biloxi, Harrison County Second Judicial District as per the map or plat thereof
on file in Plat Book 9 at Page 19 in the office of the Chancery Clerk at the
Court House in Biloxi, Harrison County Second Judicial District, Mississippi and
run North 83 degrees 25 minutes 27 seconds West along the south right of way
line of U.S. Highway 90 for 98.37 feet; thence run North 82 degrees 14 minutes
40 seconds West along the south right of way line of U.S. Highway 90 for 101.07
feet; thence run North 79 degrees 57 minutes 09 seconds West along the south
right of way line of U.S. Highway 90 for 110.45 feet to an "X" scribed in
concrete for the POINT OF BEGINNING.

From said POINT OF BEGINNING, run South 00 degrees 42 minutes 02 seconds East
for 415.84 feet to an "X" scribed in concrete; thence run South 89 degrees 20
minutes 48 seconds West for 20.98 feet to an "X" scribed in concrete; thence run
North 42 degrees 47 minutes 11 seconds West for 127.48 feet to a nail set in a
wooden bulkhead; thence run North 00 degrees 27 minutes 42 seconds West for
343.52 feet to an "X" scribed in concrete on the south right of way line of U.S.
Highway 90; thence run South 78 degrees 42 minutes 32 seconds East along the
south right of way line of U.S. Highway 90 for 107.33 feet back to the POINT OF
BEGINNING.

Said parcel of land is part of Biloxi Section Block 130 in Fractional Section
27, Township 7 South, Range 9 West, Biloxi, Harrison County Second Judicial
District, Mississippi.

                                  Page 7 of 16
                                   EXHIBIT N-1
<Page>

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                              EXHIBIT A (CONTINUED)

Issuing Office File No.: 2003-10-01E

                               LEGAL DESCRIPTION:
                                    PARCEL 6
                               FEE SIMPLE INTEREST

COMMENCE at an iron rod at the northeast corner of Harbor View Condominiums,
Biloxi, Harrison County Second Judicial District as per the map or plat thereof
on file in Plat Book 9 at Page 19 in the office of the Chancery Clerk at the
Court House in Biloxi, Harrison County Second Judicial District, Mississippi and
run North 83 degrees 25 minutes 27 seconds West along the south right of way
line of U.S. Highway 90 for 98.37 feet; thence run North 82 degrees 14 minutes
40 seconds West along the south right of way line of U.S. Highway 90 for 101.07
feet; thence run North 79 degrees 57 minutes 09 seconds West along the south
right of way line of U.S. Highway 90 for 110.45 feet to an "X" scribed in
concrete; thence run North 78 degrees 42 minutes 32 seconds West along said
south right of way line for 107.33 feet to and for the POINT OF BEGINNING.

From said POINT OF BEGINNING, run South 00 degrees 27 minutes 42 seconds East
for 343.52 feet; thence run North 42 degrees 47 minutes 11 seconds West for 7.38
feet; thence run North 50 degrees 24 minutes 44 seconds West for 159.85 feet;
thence run North 38 degrees 12 minutes 35 seconds West for 27.81 feet; thence
run North 00 degrees 32 minutes 57 seconds West for 248.40 feet to a point on
the south right of way line of U.S. Highway 90 (Beach Boulevard); thence run
South 76 degrees 47 minutes 55 seconds East along the south right of way line of
U.S. Highway 90 for 148.95 feet back to the POINT OF BEGINNING.

Said parcel of land is part of Biloxi Section Block 130 in Fractional Section
27, Township 7 South, Range 9 West, Biloxi, Harrison County Second Judicial
District, Mississippi.

                                  Page 8 of 16
                                   EXHIBIT N-1
<Page>

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                              EXHIBIT A (CONTINUED)

Issuing Office File No.: 2003-10-01E

                               LEGAL DESCRIPTION:
                                    PARCEL L1
                          ("Existing Lameuse Street")*
          LEASEHOLD INTEREST IN AIRSPACE WITH GROUND SUPPORT STRUCTURES
                           AND NON-EXCLUSIVE EASEMENT

AIRSPACE:

LOWER BOUNDARY is the horizontal plane at an elevation of 14 feet above the
surface grade of the roadway as first constructed in conjunction with the
improvements contemplated by the Lease and Air Rights Agreements with the City
of Biloxi, Mississippi, more particularly described in SCHEDULE B hereof.

UPPER BOUNDARY is the horizontal plane at the maximum elevation permitted by
applicable law.

PERIMETRICAL BOUNDARIES projected vertically to intersect the Upper and Lower
Boundaries as follows:

BEGIN at an iron rod at the northeast corner of Harbor View Condominiums as per
the map or plat thereof on file in Plat Book 9 at Page 9 on file in the office
of the Chancery Clerk at the Court House in Biloxi, Harrison County Second
Judicial District, Mississippi and run South 00 degrees 31 minutes 32 seconds
East along the east line of said Harbor View Condominiums for 239.05 feet;
thence run North 89 degrees 28 minutes 33 seconds East for 3.66 feet; thence run
South 89 degrees 51 minutes 31 seconds East for 35.92 feet; thence run North 00
degrees 22 minutes 56 seconds West for 234.78 feet to a point on the south right
of way line of Beach Boulevard (U.S. Highway 90); thence run North 83 degrees 51
minutes 05 seconds West along said south right of way for 40.44 feet back to the
POINT OF BEGINNING.

Said parcel of land is part of Biloxi Section Blocks 100 and 130, Biloxi,
Harrison County Second Judicial District, Mississippi

GROUND SPACE FOR SUPPORT STRUCTURES AND NON-EXCLUSIVE EASEMENT ONLY AS
CONTEMPLATED BY THE LEASE AND AIR RIGHTS AGREEMENTS WITH THE CITY OF BILOXI,
MISSISSIPPI, MORE PARTICULARLY DESCRIBED IN SCHEDULE B HEREOF:

See the survey description recited above as the basis for the perimetrical
boundaries of the Airspace.

*This label is provided for convenience of reference only as this parcel is so
identified in the Lease and Air Rights Agreement more particularly described in
Item 21 of SCHEDULE B - SECTION 2 of the policy and is not intended to alter or
limit the legal description.

                                  Page 9 of 16
                                   EXHIBIT N-1
<Page>

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                              EXHIBIT A (CONTINUED)

Issuing Office File No.: 2003-10-01E

                               LEGAL DESCRIPTION:
                                    PARCEL L2
                        ("Lameuse Street Parking Area")*
                               LEASEHOLD INTEREST

BEGIN at the northwest corner of Mariner's Harbor Condominiums, Biloxi, Harrison
County 2nd Judicial District, Mississippi as per the map or plat thereof on file
in the office of the Chancery Clerk at the Court House in Biloxi, Harrison
County 2nd Judicial District, Mississippi and run South 00 degrees 31 minutes 32
seconds East along the west line of said Mariner's Harbor Condominiums for
176.25 feet; thence run West for 21.29 feet to the east right of way line of
LAMEUSE Street; thence run North 00 degrees 22 minutes 56 seconds West along
said east right of way line for 178.50 to the south right of way line of Beach
Boulevard (U.S. Highway 90); thence run Easterly along said south right of way
line and along a non-tangential curve to the left (having a radius of 2323.00
feet, an internal angle of 00 degrees 31 minutes 03 seconds and being subtended
by a chord distance of 20.98 feet along a bearing of South 83 degrees 50 minutes
55 seconds East) for 20.98 feet back to the POINT OF BEGINNING.

Said parcel of land is part of Biloxi Section Block 100, Biloxi, Harrison County
Second Judicial District, Mississippi.

*This label is provided for convenience of reference only as this parcel is so
identified in the Lease and Air Rights Agreement more particularly described in
Item 21 of SCHEDULE B - SECTION 2 of the policy and is not intended to alter or
limit the legal description.

                                  Page 10 of 16
                                   EXHIBIT N-1
<Page>

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                              EXHIBIT A (CONTINUED)

Issuing Office File No.: 2003-10-01E

                               LEGAL DESCRIPTION:
                                    PARCEL L3
                     ("Existing East - West Service Road")*
          LEASEHOLD INTEREST IN AIRSPACE WITH GROUND SUPPORT STRUCTURES
                           AND NON-EXCLUSIVE EASEMENT

AIRSPACE:

LOWER BOUNDARY is the horizontal plane at an elevation of 14 feet above the
surface grade of the roadway as first constructed in conjunction with the
improvements contemplated by the Lease and Air Rights Agreements with the City
of Biloxi, Mississippi, more particularly described in SCHEDULE B hereof.

UPPER BOUNDARY is the horizontal plane at the maximum elevation permitted by
applicable law.

PERIMETRICAL BOUNDARIES projected vertically to intersect the Upper and Lower
Boundaries as follows:

COMMENCE at the northwest corner of Mariner's Harbor Condominiums, Biloxi,
Harrison County 2nd Judicial District, Mississippi as per the map or plat
thereof on file in the office of the Chancery Clerk at the Court House in
Biloxi, Harrison County 2nd Judicial District, Mississippi and run South 00
degrees 31 minutes 32 seconds East along the west line of said Mariner's Harbor
Condominiums for 176.25 feet to and for the POINT OF BEGINNING.

From said POINT OF BEGINNING run West for 21.29 feet; thence run South 00
degrees 22 minutes 56 seconds East for 56.28 feet; thence run South 89 degrees
56 minutes 41 seconds East for 420.11 feet; thence run South 49 degrees 00
minutes 58 seconds East for 15.62 feet; thence run North 88 degrees 36 minutes
21 seconds East for 14.73 feet; thence run North 00 degrees 33 minutes 17
seconds West for 55.93 feet; thence run South 89 degrees 46 minutes 41 seconds
West for 68.44 feet; thence run South 00 degrees 36 minutes 03 seconds East for
20.05 feet; thence run North 89 degrees 45 minutes 09 seconds West for 108.51
feet; thence run North 00 degrees 50 minutes 05 seconds West for 20.00 feet;
thence run South 89 degrees 37 minutes 04 seconds West for 140.06 feet; thence
run South 00 degrees 22 minutes 56 seconds East for 18.33 feet; thence run South
88 degrees 59 minutes 05 seconds West for 107.95 feet; thence run North 00
degrees 31 minutes 32 seconds West for 31.66 feet back to the POINT OF
BEGINNING.

Said parcel of land is part of Biloxi Section Block 100, Biloxi, Harrison County
Second Judicial District, Mississippi.

GROUND SPACE FOR SUPPORT STRUCTURES AND NON-EXCLUSIVE EASEMENT ONLY AS
CONTEMPLATED BY THE LEASE AND AIR RIGHTS AGREEMENTS WITH THE CITY OF BILOXI,
MISSISSIPPI, MORE PARTICULARLY DESCRIBED IN SCHEDULE B HEREOF:

See the survey description recited above as the basis for the perimetrical
boundaries of the Airspace.

*This label is provided for convenience of reference only as this parcel is so
identified in the Lease and Air Rights Agreement more particularly described in
Item 21 of SCHEDULE B - SECTION 2 of the policy and is not intended to alter or
limit the legal description.

                                  Page 11 of 16
                                   EXHIBIT N-1
<Page>

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                              EXHIBIT A (CONTINUED)

Issuing Office File No.: 2003-10-01E

                               LEGAL DESCRIPTION:
                                    PARCEL L4
                          ("East - West Service Road")*
          LEASEHOLD INTEREST IN AIRSPACE WITH GROUND SUPPORT STRUCTURES
                           AND NON-EXCLUSIVE EASEMENT
AIRSPACE:

LOWER BOUNDARY is the horizontal plane at an elevation of 14 feet above the
surface grade of the roadway as first constructed in conjunction with the
improvements contemplated by the Lease and Air Rights Agreements with the City
of Biloxi, Mississippi, more particularly described in SCHEDULE B hereof.

UPPER BOUNDARY is the horizontal plane at the maximum elevation permitted by
applicable law.

PERIMETRICAL BOUNDARIES projected vertically to intersect the Upper and Lower
Boundaries as follows:

COMMENCE at the northwest corner of Mariner's Harbor Condominiums, Biloxi,
Harrison County 2nd Judicial District, Mississippi as per the map or plat
thereof on file in the office of the Chancery Clerk at the Court House in
Biloxi, Harrison County 2nd Judicial District, Mississippi and run South 00
degrees 31 minutes 32 seconds East along the west line of said Mariner's Harbor
Condominiums for 176.25 feet to and for the POINT OF BEGINNING.

From said POINT OF BEGINNING run East for 394.64 feet; thence run South 00
degrees 42 minutes 33 seconds East for 10.75 feet; thence run South 89 degrees
46 minutes 41 seconds West for 38.03 feet; thence run South 00 degrees 36
minutes 03 seconds East for 20.05 feet; thence run North 89 degrees 45 minutes
09 seconds West for 108.51 feet; thence run North 00 degrees 50 minutes 05
seconds West for 20.00 feet; thence run South 89 degrees 37 minutes 04 seconds
West for 140.06 feet; thence run South 00 degrees 22 minutes 56 seconds East for
18.33 feet; thence run South 88 degrees 59 minutes 05 seconds West for 107.95
feet; thence run North 00 degrees 31 minutes 32 seconds West for 31.66 feet back
to the POINT OF BEGINNING.

Said parcel of land is part of Biloxi Section Block 100, Biloxi, Harrison County
Second Judicial District, Mississippi.

GROUND SPACE FOR SUPPORT STRUCTURES AND NON-EXCLUSIVE EASEMENT ONLY AS
CONTEMPLATED BY THE LEASE AND AIR RIGHTS AGREEMENTS WITH THE CITY OF BILOXI,
MISSISSIPPI, MORE PARTICULARLY DESCRIBED IN SCHEDULE B HEREOF:

See the survey description recited above as the basis for the perimetrical
boundaries of the Airspace.

*This label is provided for convenience of reference only as this parcel is so
identified in the Lease and Air Rights Agreement more particularly described in
Item 21 of SCHEDULE B - SECTION 2 of the policy and is not intended to alter or
limit the legal description.

                                  Page 12 of 16
                                   EXHIBIT N-1
<Page>

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                              EXHIBIT A (CONTINUED)

Issuing Office File No.: 2003-10-01E

                               LEGAL DESCRIPTION:
                                    PARCEL L6
                          ("Lameuse Street Extension")*
                             NON-EXCLUSIVE EASEMENT

COMMENCE at the northwest corner of Mariner's Harbor Condominiums, Biloxi,
Harrison County 2nd Judicial District, Mississippi as per the map or plat
thereof on file in the office of the Chancery Clerk at the Court House in
Biloxi, Harrison County 2nd Judicial District, Mississippi and run South 00
degrees 31 minutes 32 seconds East along the west line of said Mariner's Harbor
Condominiums for 176.25 feet; thence run West for 21.29 feet; thence run South
00 degrees 22 minutes 56 seconds East for 56.28 feet to and for the POINT OF
BEGINNING.

From said POINT OF BEGINNING run South 89 degrees 56 minutes 41 seconds East for
16.57 feet; thence run South 00 degrees 28 minutes 40 seconds East for 165.94
feet; thence run South 43 degrees 48 minutes 30 seconds East for 45.54 feet;
thence run South 00 degrees 22 minutes 16 seconds East for 80.74 feet; thence
run North 89 degrees 52 minutes 45 seconds West for 70.46 feet; thence run South
00 degrees 42 minutes 50 seconds East for 111.52 feet; thence run South 89
degrees 07 minutes 28 seconds West for 12.17 feet; thence run North 00 degrees
29 minutes 01 second West for 250.29 feet; thence run North 01 degree 44 minutes
55 seconds West for 16.59 feet; thence run North 83 degrees 11 minutes 02
seconds West for 1.20 feet; thence run North 00 degrees 23 minutes 59 seconds
West for 124.18 feet; thence run South 89 degrees 51 minutes 31 seconds East for
35.92 feet back to the POINT OF BEGINNING.

Said parcel of land is part of Biloxi Section Blocks 100 and 130, Biloxi,
Harrison County Second Judicial District, Mississippi.

*This label is provided for convenience of reference only as this parcel is so
identified in the Lease and Air Rights Agreement more particularly described in
Item 21 of SCHEDULE B - SECTION 2 of the policy and is not intended to alter or
limit the legal description.

                                  Page 13 of 16
                                   EXHIBIT N-1
<Page>

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                              EXHIBIT A (continued)

Issuing Office File No.: 2003-10-01E

                               LEGAL DESCRIPTION:
                                    PARCEL L9
                    PUBLIC TRUST TIDELANDS LEASEHOLD INTEREST

COMMENCE at the northeast corner of Harbor View Condominiums, Biloxi, Harrison
County 2nd Judicial District, Mississippi as per the map or plat thereof on file
in the office of the Chancery Clerk at the Court House in Biloxi, Harrison
County 2nd Judicial District and run South 00 degrees 31 minutes 32 seconds East
for 239.05 feet; thence run North 89 degrees 28 minutes 33 seconds East for 3.66
feet; thence run South 00 degrees 23 minutes 59 seconds East for 124.18 feet;
thence run South 83 degrees 11 minutes 02 seconds East for 1.20 feet; thence run
South 01 degree 44 minutes 55 seconds East for 16.59 feet; thence run South 89
degrees 00 minutes 06 seconds West for 1.16 feet to and for the POINT OF
BEGINNING.
From said POINT OF BEGINNING run South 89 degrees 00 minutes 06 seconds West for
100.62 feet; thence run North 07 degrees 17 minutes 25 seconds West for 5.98
feet; thence run North 49 degrees 17 minutes 42 seconds West for 9.81 feet;
thence run South 89 degrees 20 minutes 48 seconds West for 220.99 feet; thence
run North 42 degrees 47 minutes 11 seconds West for 134.86 feet; thence run
North 50 degrees 24 minutes 44 seconds West for 159.85 feet; thence run North 38
degrees 12 minutes 35 seconds West for 27.81 feet; thence run South 00 degrees
32 minutes 57 seconds East for 559.19 feet to the north line of the Biloxi
Channel; thence run South 88 degrees 06 minutes 44 seconds East along said north
line of the Biloxi Channel for 559.07 feet; thence run North 00 degrees 23
minutes 25 seconds West for 346.84 feet back to the POINT OF BEGINNING

                                  Page 14 of 16
                                   EXHIBIT N-1
<Page>

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                             SCHEDULE B - SECTION 1

                                  REQUIREMENTS

Issuing Office File No.: 2003-10-01E

All references herein to Deed Book or Deed of Trust Book refer to those records
located in the Office of the Chancery Clerk of the Second Judicial District of
Harrison County, Mississippi.

THE FOLLOWING REQUIREMENTS MUST BE MET:

1.   Furnish satisfactory evidence of disbursement of $[___________] of the
proceeds of the notes to ________________ within 5 business days of the date of
this commitment.

2.   Notice from the Disbursement Agent to the Issuing Agent for the Company,
Balch & Bingham, LLP, by telephone or by email on the disbursement date before
making such disbursement and the Issuing Agent on behalf of the Company does not
rescind this commitment in such telephone call or email, as the case may be. .

                                  Page 15 of 16
                                   EXHIBIT N-1
<Page>

                     FIRST AMERICAN TITLE INSURANCE COMPANY

                             SCHEDULE B - SECTION 2

                                   ENDORSEMENT

Issuing Office File No.: 2003-10-01E

THE ENDORSEMENT TO BE ISSUED WILL BE IN THE FOLLOWING FORM:

Based upon satisfactory evidence that the insured or its Disbursement Agent has
made an advance to __________________ in the sum of $ __________, which is a
portion of the indebtedness evidenced by the note or notes secured by the
insured deed of trust, the Company hereby insures the owner of the indebtedness
secured by the insured deed of trust against loss or damage which the insured
shall sustain by reason of:

The existence of any lien, encumbrance or other matter affecting the estate or
interest referred to in SCHEDULE A, recorded in the public records subsequent to
Date of Policy, except: NONE [OR LIST ANY NEW MATTERS OF RECORD WITH AFFIRMATIVE
COVERAGE FOR LOSS OR DAMAGE RESULTING FROM SAME]

The existence of any subsisting tax or assessment lien which is prior to the
insured deed of trust, except: NONE OTHER THAN AD VALOREM TAXES FOR THE CURRENT
YEAR WHICH ARE NOT YET DUE AND PAYABLE

Title to the estate or interest referred to in SCHEDULE A being vested other
than as shown in SCHEDULE A according to the public records;

The failure of the advance identified above to be secured by the insured deed of
trust;

Lack of priority of the insured deed of trust with respect to such advance, over
any liens, encumbrances and other matters shown by the public records, affecting
the estate or interest referred to in SCHEDULE A, other than those shown in
SCHEDULE B as prior to the insured deed of trust and in paragraph (2) herein,
except: NONE

Lack of priority of the lien of the insured deed of trust over any statutory
lien for services, labor or material arising out of the work of improvement
under construction or completed at the date hereof.

The coverage under the disbursement clause is hereby increased by $___________,
and the Company acknowledges that as of the effective date of this endorsement,
the amount of $_______________________ has been disbursed under the Cash
Collateral and Disbursement Agreement secured by the insured deed of trust.

This endorsement is made a part of the policy and is subject to all of the terms
and provisions thereof and of any prior endorsements thereto. Except to the
extent expressly stated, it neither modifies any of the terms and provisions of
the policy and any prior endorsements, nor does it extend the effective date of
the policy and any prior endorsements, nor does it increase the face amount
thereof.

Date:
     ----------------

First American Title Insurance Company
By: Balch & Bingham LLP, Issuing Agent

     PRO FORMA
By:
   ----------------------------------------
      Authorized Signatory

                                  Page 16 of 16
                                   EXHIBIT N-1
<Page>

            EXHIBIT N-2 TO CASH COLLATERAL AND DISBURSEMENT AGREEMENT

                      FORM OF SEPARATE TAX LOT ENDORSEMENT

                      Attached to Policy No. FA- PRO FORMA

                                    Issued By

                     FIRST AMERICAN TITLE INSURANCE COMPANY

The Company hereby assures the Insured that Parcels 2, 3, 4, 5, and 6 of the
land referred to in SCHEDULE "A" consist of separate tax parcels and said
parcels do not include any property not included within said land.

Parcel L1 and portions of Parcels L3 and L6 are not currently assessed for tax
purposes.

Parcel 1 consists of a separate tax parcel except to the extent it includes land
to be conveyed to the City of Biloxi. Any remainder of the land described in
SCHEDULE "A" which is not assessed solely to Premier Entertainment Biloxi LLC or
its predecessor is currently assessed to the City of Biloxi, Mississippi, and is
exempt from taxation.

The Company insures the insured against loss or damage in the event the
assurances herein shall prove to be incorrect.

This endorsement is made a part of the policy and is subject to all the terms
and provisions thereof and of any prior endorsements thereto. Except to the
extent expressly stated, it neither modifies any of the terms and provisions of
the policy and prior endorsements, if any, nor does it extend the effective date
of the policy and prior endorsements or increase the face amount thereof.

First American Title Insurance Company
By: Balch & Bingham LLP, Issuing Agent

     PRO FORMA
By:
   ----------------------------------------
     Authorized Signatory

F.A. Form 64
Separate Tax Lot

                                   Page 1 of 1
                                   EXHIBIT N-2

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00064-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00064-of-00352.parquet"}]]