Document:

QuickLinks
 -- Click here to rapidly navigate through this document

 
 

Exhibit 10.11    
    

AGREEMENT  

Arranged and signed in Haifa on the    day of February, 2005  

 BETWEEN  

 MATA"M—Haifa Advanced Technology Center Ltd.  

 ("The Company", "MATA"M")                             On one
side;  

 AND  

 ZORAN MICORELECTRONICS Ltd.  

 ("The Renter")                             On the other side;

	Since	 	The Company has rights on the land at the Advanced Technology Center in Haifa ("The Center") known as lot 89 in block 10730 ("The Land"), as marked in red perimtrical line on the parking and building location plan
Annex "K";
	

And since	
 	

The renter wishes to rent from MATA"M the building (as defined hereunder) that will be built on the land according to the location marked in annex "K" and which will serve in the course of the tenancy period for conducting the Renter's business as
detailed in this contract;
	

And since	
 	

The Company is interested in renting to the Renter and the Renter is interested to rent from the Company within unprotected rental the rented object as defined in the technical specification and in the conceptual design, enclosed hereto as Annexes
"A" and "B", respectively, to the agreement and constitute an integral part of the same;

        Therefore it has been declared and agreed by the parties as follows:

	1.
	Interpretation

	(a)
	With
no prejudice to the other definitions contained in this contract the following terms will be interpreted as follows: 

	 	 	"The rented object"	 	—	 	The area that will be rented to the Renter, including both the building, as defined hereunder, and the parking lot, as defined hereunder.
	

 	
 	

"The building"	
 	

—	
 	

The building due to be built on the land with a gross area of 8,400 sq.m., and which includes five stories, top roof level that includes engine rooms, rooms and technical spaces, staircases, waste room, etc.
	

 	
 	

"The parking lot"	
 	

—	
 	

100 marked parking spaces, paved and unroofed that will be rented to the Renter, according to paragraph 12(d) hereunder, as marked in the parking and building location plan enclosed hereto as Annex "K" to this agreement. To avoid any doubt, the
parking lot constitutes an integral part of the rented object, for any purpose and issue.
	

 	
 	

"The tenancy period"	
 	

—	
 	

The period defined in paragraph 7(a) hereunder including the shortened or extended tenancy period as result of any prescription of this agreement and/or as result of any law.
	 	 	 	 	 	 	 

 

	

 	
 	

"Contractual delivery day"/"Contractual delivery time"	
 	

—	
 	

The time set for the beginning of the tenancy period as per paragraph 6(a)(1) or an earlier or later time according to the prescriptions of this contract.
	

 	
 	

"Actual delivery day"/"Actual delivery time"	
 	

—	
 	

The time when the rented object is actually put at the Renter's disposal. To avoid doubts, the count of the tenancy period will start at the time of actual delivery.
	

 	
 	

"Project manager"	
 	

—	
 	

Who has been designated by MATA"M to serve as the building's construction project manager.
	

 	
 	

"The architect"	
 	

—	
 	

Architect Ilan Eldar, chosen by MATA"M for designing the rented object, or any other architect designated by MATA"M.
	

 	
 	

"The Renter's representative"	
 	

—	
 	

Who has been designated by the Renter to serve as a representative on its behalf for all issues concerning the building's construction and as its point of contact between itself and the project manager.
	

 	
 	

"The detailed design"	
 	

—	
 	

Tender level drawings, including technical specifications, list of quantities (inventory), architectural drawings, construction and finish, civil engineering drawings, including the building systems' drawings including the electromechanical systems,
electricity, air-conditioning, communication infrastructure, safety systems, elevators, etc. and including service and maintenance agreements' formulations for all the abovementioned systems, including detailed commercial conditions, to be attached
as annexes to the engagement documents with the executing contractors.
	

 	
 	

"The Center's tenants"	
 	

—	
 	

Corporations that rent and/or lease areas in the Center (as defined above) and that receive services from the Service Company at the Center (as defined in paragraph 9 hereunder).
	

 	
 	

"Gross area"	
 	

—	
 	

The external contour of each and every storey, including stone paneling and screen walls and including all the technical roofed areas built on the roof and at any other storey, and including pits, safety rooms, staircases, elevators, etc., and
excluding unroofed operation yards, gardening and development areas, access roads within the land and unroofed parking areas.
	

 	
 	

 	
 	

 	
 	

The gross area will be established at the end of the building's construction according to the "AS MADE" drawings submitted to the qualified authorities, but without prejudice to Zoran's right to claim against the text of those drawings.
	

 	
 	

"MATAM's companies"	
 	

—	
 	

The Company, the Gev-Yam Le-Karka'ot Company Ltd., Shata"m Haifa Ltd., the Haifa Economic Corporation Ltd., including mother companies, subsidiaries and related companies, as defined in the Securities Act.

2

 

	(b)
	The
paragraphs' headings have been introduced for convenience only and they are not to be used for interpretation.

	(c)
	Every
time an amount in US Dollars is mentioned in this contract, it is done for convenience only and it does not have legal validity, the sums nominated in US Dollars will be
translated into NIS at the rate of 4.455 NIS for each 1 US Dollar.

	2.
	Introduction and Annexes

The
introduction and the annexes to this contract constitute an integral part of the same. 

	3.
	Essence of the Deal

	(a)
	The
Company hereby rents to the Renter and the Renter hereby rents from the Company the rented object for the amount and in the conditions as detailed in this contract.

	(b)
	The
Company declares that it possesses the know-how, the experience, the material resources and the capability for building the rented object according to the time
schedules set for that, and that it has conducted all the reasonable necessary verifications, to the best of its knowledge, including those with the pertinent authorities, to make sure that no
essential difficulties are expected to come up, either with regard to building the rented object or to the time schedules established for that. 

The
Renter declares that it has seen the location of the area on which the building is due to be built and found it compliant with its requirements and purposes, and that it hereby waives any claim
for defect or impediment or inadequacy regarding the building's location on the abovementioned area. 

The
Renter also declares that the technical specification and the conceptual design attached as annexes to this agreement and signed by the parties have been shown to and approved by it, and they are
adequate and suit its necessities and the purpose of the rental according to this agreement. 

	(c)
	The
Renter declares that it is known to it that this contract grants it the rental right on the rented object only, and that the Company will be entitled, subject to the prescriptions
and conditions of the law, to carry out construction work of additional buildings in the vicinity of the building, at its sole discretion, and the Renter hereby explicitly gives up any suit or claim
in relation with that against the Company, as long as it does not constitute an essential offense or unreasonable disturbance to the conduct of the Renter's business at the rented object or the
prevention of access to the rented object. As far as the above construction work is going to be done by the Company, the Company undertakes and declares that all reasonable precautions will be taken
by it as necessary in order to enable the Renter reasonable use of the rented object for the rental's objective. 

Without
limiting the generality of the above said and to avoid any doubt, it is hereby made clear that all construction rights in the building belong to the Company only. 

	(d)
	The
Renter declares that it has looked up the relevant Cities Building Plan (X/1273/X) and that the rental objective, at present and in the future, complies with the objective stated
at the above mentioned plan.

	(e)
	The
Renter knows that the validity of this agreement is subject to the approval of the Company's Board of Directors. Therefore, it is agreed by the parties that before the agreement
is signed by the parties and as a condition for that signing, the approval of the Company's Board of Directors is given to the agreement's conditions and to its being signed by the Company. 

3

 

	4.
	Construction of the Rented Object and Acceptance of the Rented Object

	(a)
	The
building will be constructed by the Company according to the technical specification and the conceptual design, Annexes "A" and "B"
and will have a gross area of 8,400 sq.m. The Company will also carry out all the development work showing at the building permit that will be granted.

	(b)
	The
Company is responsible for obtaining on its account the licenses, authorizations and permits required and/or that will be required by law to build the rented object by itself or
by whomever else on its behalf.

	(c)
	The
Company declares and undertakes that the jobs carried out by it in the rented object will be of high level, befitting the MATA"M Park's character and that the building will be
constructed by experienced and professional people professionals.

	(d)
	It
is agreed that the Renter will not be liable toward the Company for any physical and/or capital damage of any kind and sort caused to any person and/or building as result and/or in
relation with the building's construction. The Company will take care of an appropriate insurance to cover damages as mentioned above. 

In
the case that the Renter is sued by a third party for a damage that the Company is liable for by this clause, then the Company will have to indemnify the Renter within 7 days from the day on
which the Renter was required to pay said amount, for any amount that the Renter is obliged to pay the third party, following a final verdict of a Court of Law, with the addition of all the expenses
incurred into by the Renter as result of the trial with the third party and without prejudice to the generality of the aforesaid, the principal, interest, linkage differentials, lawyer's fee, levies,
trial expenses, added-value tax and other expenses of any kind originating at the suit. 

Indemnification
of the Renter by the Company will be conditioned upon a notice issued to the Company regarding the proceedings against the Renter and also upon an opportunity given to the Company to
defend itself against the claims raised within said proceedings. 

	(e)
	Not
later than 60 days from signing this agreement, the architect and the Company's team of consultants will prepare and submit to the Renter a detailed design, compliant with
the technical specification and the conceptual design. 

Within
15 days from the receipt of the detailed design the Renter will check the detailed design including its compliance with the technical specification and with the conceptual design. If the
Renter does not have any observation, The Renter will approve the detailed design in writing. If the Renter detects a deviation from the above, an/or requests a modification compatible with the above,
the Renter will relay a detailed written list of the necessary modifications within the abovementioned time frame. 

In
the case that the parties agree that a discrepancy between the technical specification and conceptual design, and the detail design has been found, or in the case that the requested modification is
within the above, then the detailed design will be returned to the architect for correction and he will be required to do so as soon as possible. Immediately after correction the detailed design will
be submitted again to the Renter for approval. 

If
the parties do not reach an agreement regarding the necessary correction, the dispute will be submitted to the arbitration of the project manager on behalf of the Company and the Renter's
representative. If they do not reach an agreement, the dispute will be submitted to the decision of both parties' general managers (hereafter: The Arbitration Mechanism"). 

4

 

In
the case that it is agreed and/or decided that the requested modification is not in the category of a discrepancy between the technical specification and conceptual design and the detailed design,
or that it is not according to the above, the Renter will be entitled to make it in the framework of changes and additions as detailed hereunder. 

After
the detailed design is approved by the parties as described above, it will be attached to the contract as Annex "C" and will constitute an integral part thereof. 

In
the case that the detailed design is approved by the Renter, and after having approved it the Renter finds discrepancies between the detailed design and the technical specification and conceptual
design, the Renter is entitled to demand from MATA"M the detail design's correction, as long as the Renter does so up to 7 days before the beginning of the actual execution of the item needing
correction. 

The
Renter will be prevented from issuing any claim and/or demand concerning deviations of the detailed design from the conceptual design and technical specification that are not submitted by the
Renter until 7 days before the beginning of the actual execution of the item needing correction. 

After
the detailed design has been approved, the architect and the different consultant hired by the Company will prepare the tender's documents, in accordance with the detail design that has been
approved. 

	(f)
	After
the approval of the detailed design and throughout the execution of the project's jobs, all the details related to the execution of the jobs, such as the selection of items,
etc., will be relayed to the Renter for approval. In the case that the Renter is requested by the project manager to approve the details concerning the job's execution as above said, the Renter
undertakes to deliver its decision to the project manager within 15 days from his request. 

In
order to enable the Renter to conduct an organized and orderly process of selection of items, the Company will establish at the site, as usual and on its account, at the finishing phase of the job,
a prototype of an ordinary office. At the beginning of the jobs execution, the Company will place at the site a container with samples of the materials such as samples of paint sets, tilling,
plastering, etc. In the case that the Renter delays its decision over the abovementioned 15 days, the Company is entitled to chose the items and approve the architect's choice and at the
Company's discretion, so that in any case the actual delivery of the rented object to the Renter is not delayed. 

	(g)
	The
Renter, on its own or thru the project manager on behalf of the Renter, will be entitled to apply to MATA"M in writing requesting modifications and/or jobs in addition to those
included in the technical specification and in the detailed design (Annexes "A", "B" and "C"). 

In
such case MATA"M will submit to the Renter a reasoned and detailed estimate of the cost of the amendments and modifications including the cost of design and consultants fee
("Cost-Estimate of Additions and Modifications") and will also inform the expected delay in the actual delivery, if such delay is expected, due to carrying out the additions and
modifications. 

The
estimate submitted to the Renter will be based, as far as feasible, on the unit prices contained in the agreement between the Company and the executing contractor. If the Renter requests a binding
price-quotation for the additions and modifications, the Company will submit said quotation. 

The
Renter will confirm to MATA"M in writing within 14 days that it will bear the cost of the additions and modifications as defined hereunder and that it is ready to accept the expected delay
in delivery and in such a case MATA"M will carry out the additions and modifications, 

5

 

on
the Renter's account, as detailed in the application. In the case of dissension, the measures contemplated by the arbitration mechanism set up in this agreement will be applied. 

It
is hereby agreed that in the case of delay in the actual delivery as result of the Renter's request to make additions and modifications as described above, the parties will act as per
paragraph 4(i) hereunder. 

It
is hereby clarified that the estimate of the additions and modifications is only a valuation and it is not binding on MATA"M nor does it decrease from the Renter's commitment to full payment for
the cost of the additions and modifications as defined hereunder. 

If
the Renter does not approve introducing the additions within the above mentioned 14 days, MATA"M will complete the rented object according to the technical specification, the request for
permit and the detailed design, and the Renter hereby desists from any claim against MATA"M due to that. 

It
is agreed between the parties that a design modification that usually does not involve additional payment to the designer, will not be charged on the Renter as and additional design cost. 

It
is hereby clarified that the Renter's request to introduce additions and modifications will compel the Renter to cover the cost of the additions and modifications to MATA"M as detailed hereunder in
this paragraph and also all the costs of designing the additions and modifications (including, not limiting the generality of the above said, the consultants' fee). In order to make the additions and
modifications MATAM will engage contractors and/or suppliers according to its procedures and at its discretion, in its usual engagement conditions for ordering jobs of this kind done for MATAM. 

	(h)
	The
Renter will pay MATAM the cost of the additions and modifications as follows: 

Based
on the estimate on the introduction of the additions and modifications from MATA"M as stated hereunder and as a condition for the execution of the additions and modifications by MATA"M, the
Renter will deposit at MATA"M an automatic, unconditional bank guarantee with the text attached hereto as Annex "H/1" to this agreement, for the amount of half the cost estimate of the additions and
modifications with the addition of VAT as required by law. It is agreed that the abovementioned guarantee will be submitted only in the case that MATA"M's open balance to the contractors due to the
additional jobs exceeds the amount of $100,000 in total and only for the open balance exceeding $100,000. 

Payment
for the cost of introduction of the additions and modifications, as the case may be, will made in partial payments according to the advance of the additions and modifications actual execution
against the contractor's approved invoices submitted for payment by MATA"M to the Renter. Each and every payment will be made by the Renter before and close to the time due for payment by MATA"M to
the contractor. 

Upon
and against the payment of the invoice for the additions and modifications, the Company will return to the Renter the bank guarantee deposited according to this paragraph, if deposited. To avoid
any doubt, the Renter will not be entitled to deduct and/or set off any sum from the payment due for the additions and modifications. 

"Cost of introduction of additions and modifications"—signifies the amounts paid by MATA"M to the designers, consultants, contractors and
suppliers as per the conditions of the agreements with them and according to the invoices they submit for an excess in quantity or quality relative to the technical specification, the conceptual
design and the drawing ("garmoshka"), or any change requested after having completed the detailed design, presented to the Renter and approved by the Company, at the Renter's request, with the
addition of 

6

 

management
and inspection expenses at a rate of 6% of the invoices submitted by the consultants, the designers, the contractors and the suppliers, and any other direct expense related to or resulting
from the introduction of the additions and the modifications except for financing expenses (distinguished from linkage and interest due in the case of payment delays). 

The
cost of the additions and modifications will be linked according to the conditions agreed upon between MATA"M and each and every contractor that carried out the additions and modifications, as the
case may be, and as far as feasible according to the agreements between MATA"M and the contractors. 

	(i)
	In
any case of delay in the execution of the jobs, cause by an action or lack of action of the Renter and/or anyone on its behalf, the following mechanism will apply: 

For
the first month of delay as mentioned above the contractual delivery time will be delayed according to the actual delivery time, meaning that no payment for the rented object will be charged on
the Renter. 

For
the second month of delay as stated above, or any part of it, the Renter will pay MATA"M pre-estimated liquidated damages equal to two thirds of the monthly rent for the rented object,
with no right to any additional remedy. 

After
two months delay the contractual delivery time will be due and the Renter will begin to bear all the payments due by this agreement for the rented object, although it has not been delivered yet. 

To
avoid any doubt, in relation with this paragraph, the Renter's action and/or omission that can delay work—including modifications and/or additions requested by the Renter in the course
of the job's execution, delay in the Renter's decision making as mentioned in item (c) above, delay in the submittal of drawings, omission of information on time, halting work by the Renter,
delay in the jobs done by the Renter in the rented object and so forth, action or omission on which the Company notified the Renter in writing, immediately upon MATA"M's becoming aware of the
existence of said action and/or omission. Immediately next to the end of the delay caused by the Renter, MATA"M will notify the Renter in writing the time delay caused. 

	(j)
	MATA"M
undertakes to carry out and complete the building's construction by an experienced and expert contractor and put the rented object at the Renter's disposal according to the
prescriptions of this contract for the tenancy period after having completed the building's construction so as to enable the Renter reasonable and undisturbed use of the building according to the
rental's objective.

	(k)
	MATA"M
will enable the Renter, or anyone on its behalf, to currently visit the project's construction site, while observing the safety instructions habitual at the site at the time of
the visit.

	(l)
	Beginning
at the time of signing the contract and until the Renter is handed-over hold of the rented object, MATA"M and the Renter will hold coordination and reporting
meetings on a weekly basis, and/or as necessary by mutual agreement between the parties.

	(m)
	If
necessary and not less than once a month, in coordination with the project manager, coordination and reporting meetings will be held in presence of the parties' representatives and
in presence of the consultants engaged in the project, including the architect. As far as one of the parties to the agreement requires, a coordination meeting will be set as urgently as feasible in
the specific circumstances. 

7

 

	(n)
	After
completion of the building and handing it over to the Renter's hold according to this contract, MATA"M will deliver to the Renter the installation books and "as made" drawings
of all the building's construction jobs and all its systems.

	(o)
	Without
limiting the Company's liability for the quality of the building's construction, the Company will be responsible toward the Renter for everything related to the quality of
finish jobs, and that for a period of a year from the time of delivery. 

Without
prejudice to the generality of the above said, the Company will efface "Transfer" at the end of the abovementioned year of guarantee, the guarantee of the finish jobs and systems contractors,
as far as said guarantee continues beyond the Company's one year guarantee. 

	5.
	Jobs in Parallel

	(a)
	Subject
to the above stated and hereinafter, the Company will enable the Renter or anyone on its behalf including its contractors and workers to carry out jobs in the rented object
parallel with the project's execution, as long as the following conditions are fulfilled:

	(1)
	The
jobs will be done subject to what is said hereunder, immediately after the Company obtains the approval of the detailed design for the parallel jobs, which will be submitted by
the Renter to the Company for approval. 

The
Renter will be entitled to do the jobs in parallel 6 months before the delivery date. In the case that the parallel jobs can be carried out before said time, according to MATA"M's working
rate at the building, MATA"M will enable the Renter to carry out the jobs as early as possible, subject to prior coordination. 

In
case of delay in the actual delivery as result of the above Renter's parallel jobs, without coordination with the Company and/or the contractors on its behalf and/or in contradiction to the
Company's instructions and/or those of the project manager and/or those of the law, the aforementioned prescriptions in paragraph 4(i) will apply, as long as the Company has issued a
written warning to the Renter on the expected delay, immediately upon the Company's becoming aware of its existence. 

	(2)
	Signing
a quadruple agreement (between the Company, the Renter, the prime-contractor on behalf of the Company and the contractor executing the parallel jobs on behalf of the Renter),
a copy of which is enclosed hereto as Annex "D" to this agreement, and payment of the prime-contractor's commission and coordination expenses amounting to 4% of the cost of the parallel jobs,
according to the final and approved invoices of the contractors engaged in the execution of the parallel jobs which will be submitted by the Renter to MATA"M. The commission payment will be made by
the Renter currently + 30 days from the date of payment of each invoice to a contractor employed by the Renter as described above. 

To
avoid any doubt, signing a quadruple agreement as mentioned above will constitute a condition for the commencement of the parallel jobs. 

	(3)
	An
agreement between the Renter and safety and installation consultants, as required by the project manager, employed by the Company in the project.

	(4)
	It
is hereby clarified that any unexpected delay in the actual delivery time originating at and/or as result of the parallel jobs carried out by the Renter is the Renter's sole
responsibility and the prescriptions of paragraph 4(i) above will apply, as long as the Company issued a written warning to the Renter on the cause for the expected delay, immediately
upon the Company's becoming aware of its existence. 

8

 

	(5)
	It
is agreed that the Company will be entitled to stop the Renter's work for a limited period of time if one of the aforementioned conditions is violated in a essential and
substantial manner, and up to the time when the violation has been corrected, as long as the following accumulative conditions have been met:

	(a)
	The
project manager informed the Renter without delay on the violation.

	(b)
	An
immediate warning to the parties' general managers was issued that the violation had not been corrected.

	(c)
	The
violation was not corrected immediately after having warned the general managers.

	(6)
	Nevertheless,
as much as the parallel jobs are of the kind that needs any sort of authorization to obtain Form 4 to inhabit the rented object, the Renter undertakes to deliver
said authorizations to MATA"M, not later than a month before the actual delivery date. It is made clear that as far as known to the parties, the parallel jobs are not of the kind that needs any sort
of authorization to obtain Form 4.

	(7)
	The
Renter undertakes that in the case that opening foundation walls is required to introduce equipment in the framework of the parallel jobs, this will be done only by means of the
aluminum contractor of the rented object, and on his account.

	(b)
	The
Renter is liable by law for any corporal and/or property damage of any sort and kind whatever inflicted to any person and/or to the rented object and/or to their contents as
result of and/or in relation with the parallel jobs due to damages caused and/or occurred as result of a neglectful action and/or omission of the Renter or anyone on its behalf. The Renter will insure
its work at the rented object by any insurance necessary to cover any damage as mentioned above.

	(c)
	The
Renter is responsible for obtaining on its account of all the permits needed and/or that will be needed by any law in order to carry out the parallel jobs by itself and/or by
anyone on its behalf in the building, including the Standards Institution and fire fighting, if needed (for both, the design as well as the execution). The Company will assist the Renter as much as
possible to obtain the above permits as long as such assistance is not construed as imposing on it any liability including without limiting the generality of the above said, any financial charge.

	(d)
	The
Renter declares and undertakes that the jobs executed in parallel at the rented object will be of high level and worthy of the MATA"M park.

	(e)
	Without
limiting the Renter's liability as established above and hereinafter in this agreement, the Renter will take care on its account and responsibility in addition to the
insurances mentioned in the Insurance Annex, of an appropriate all-risk insurance coverage in relation with the jobs done in parallel. A waiver clause will be included in said insurances
of the right of transfer against MATA"M as defined in the Insurance Annex, and MATA"M will be added as beneficiary according to the policy.

	(f)
	It
is hereby made clear that in the case that the Renter's jobs impose changes in the jobs that the Company has to carry out as per this contract, including its annexes, which involve
additional expenses, those expenses will be charged on the Renter as long as the Company notifies the Renter in writing and in detail about the additional expenses next to becoming aware of them. 

The
Company will examine the Renter's jobs as far as their details are relayed to the Company by the Renter and will inform the Renter as early as possible and in advance (as 

9

 

much
as possible before the beginning of their execution) whether the Renter's job require, to the best of the Company's knowledge, changes in the jobs the Company has to do. 

To
avoid any doubt, whatever has been said herein does not impose on the Company any liability for and/or in relation with the Renters jobs. 

The
Company will not abstain from agreeing to the Renter's jobs for reasons that are not plausible. 

	6.
	Transfer of Tenure of the Rented Object

	 	(a)	(1)	 	Subject to the fulfillment of the parties' commitments as established in this agreement, the contractual delivery date will be 20 (twenty) months from the date of signing this agreement, namely on
the                .
	

 	

 	

 	
 	

In spite of the above said it is explicitly agreed that MATA"M is entitled to advance the contractual delivery time by up to 60 days, this by giving the Renter an early notification of at least 6 months in advance of the advanced
contractual delivery date. Advancing the delivery date as described above will not be considered as incompliance on MATA"M's side and the Renter does not and will not have any complaints and/or claims and/or demands from MATA"M in this
respect.
	

 	

 	

(2)	
 	

It is known to the Renter that the building permit is due to be received within 4 months from the date of signing this agreement, namely until
the    day            . The Company undertakes to do everything in its power in a reasonable manner to advance the issuance of the building permit as early as possible.
In the case of delays in obtaining the building permit, for a reason that does not depend on the Company, the delivery date will be delayed respectively to the delay period.
	

 	

 	

 	
 	

In the case that the building permit is not granted within 9 from the date of signing this contract, namely until
the            day            , the Renter will be entitled to terminate this agreement. To avoid any doubt, The Renter will have
no complaints and/or demands and/or claims against the Company in this issue, and it will be entitled to no remedy other than the agreements termination, as long as the delay is not caused by the Company.
	

 	

 	

(3)	
 	

It is agreed, that in the case of a delay of up to 30 days in the delivery of the rented object from the contractual delivery date, the original or the early, as the case may be, the Renter will not be entitled to any financial remedy and/or
other from the Company.
	

 	

 	

 	
 	

In the case of a delay longer than 30 days in the delivery of the rented object from the contractual delivery date, the original or the early, as the case may be, the Renter will be entitled to receive from the Company for each month of delay in
the delivery an estimated and liquidated compensation in advance, of an amount equal to $30,000. For a delay of part of a month the Renter will be entitled to receive a proportional part of the above agreed compensation. The above said can not
prevent the Renter from claiming damages, if those exceed the agreed compensation.
	

 	

 	

 	
 	

The financial compensation remedy (including compensation higher than the agreed compensation) is the only remedy the Renter is entitled to in case of a delay in delivery which does not exceed 6 months.
	

 	

 	

 	
 	

If delivery is delayed by more than 6 months, it will be considered as a substantial incompliance of the agreement that entitles the Renter to terminate the agreement in an immediate manner.
	 	 	 	 	 

10

 

	

 	

 	

 	
 	

The above will not apply in the case that the delay and/or hindrance in the design's completion and/or in the delivery of the building are the result of force majeure and/or modifications and/or additions required by the Renter as described in
paragraph 4 and/or of parallel jobs done by the Renter or by anyone on its behalf according to the prescriptions of this contract and/or for reasons out of the Company's control as detailed in items (a)(2), (b)(6) and (c) hereinafter which
will not constitute a violation of the contract by the Company, and the Renter does not and will not have complaints and/or claims and/or demands from the Company in this respect.
	

 	

 	

 	
 	

To avoid any doubt, it is made clear that in any case of delay in the delivery of the rented object to the Renter relative to the contractual delivery date, the original or the early one, as the case may be, for a reason that does not depend on the
Renter, the Renter will not have to pay rent for the delay period.
	

 	

 	

(4)	
 	

The parties undertake appearing on the actual delivery date, namely the    day            . In order to deliver and receive the rented object subject to the Company's
notification to the Renter about the actual delivery date. It is agreed and declared by the parties that as a precondition for delivery of tenure on the rented object, MATA"M will be entitled to require the Renter to sign a delivery protocol
mentioned hereinafter in item (b)(2) and a certificate of insurance, as per Annex "J" to this contract.
	

 	

(b)	

(1)	
 	

Approximately 4 weeks before the actual delivery date, namely on the        day            , and following prior coordination, a first inspection of
the rented object will be conducted by representatives of the Company and the Renter who will check and confirm to the parties that the rented object is ready for delivery and has been built according to the prescriptions of this contract, including
its annexes, and according to the detailed design and approved modifications.
	

 	

 	

 	
 	

The parties' representatives will edit a protocol where all the defects found in the first inspection of the rented object, if found, will be detailed ("Defects
Protocol").
	

 	

 	

(2)	
 	

10 days before the actual delivery date, namely on the    day            , another inspection of the rented object will be performed, by the parties' representatives,
 in which the repairs made by the Company will be checked according to the defects protocol.
	

 	

 	

 	
 	

On the occasion of the additional inspection, the parties' representatives will edit another protocol, where the rented object's defects still remaining will be detailed, as well as newly found defects, if found, in the course of the additional
inspection ("Additional Inspection Protocol").
	

 	

 	

(3)	
 	

On the occasion of the actual delivery, namely on the    day            , the representatives of the Company and the Renter will edit a delivery protocol that will be
attached to this contract as Annex "E" to it and will be an integral part thereof. Signing the protocol will constitute the Renter's confirmation that MATA"M fully completed its commitments regarding the rented object, and that it does not have nor
will it have any complaints on the rented object, except for the defects listed in the additional inspection protocol and that have not been repaired by the Company yet and also defects and/or inadequacies and/or additional deficiencies detected
after the additional inspection except complaints on a defect that could not be detected in the reasonable inspection performed by the Renter ("Delivery Protocol").
	 	 	 	 	 

11

 

	

 	

 	

(4)	
 	

In the case that repairs are required following any of the inspections, including those needed to adapt the rented object to the above said, and those repairs do not prevent the Renter from reasonably using the rented object, the Company will make
them within 60 days from the delivery date or as soon as possible in urgent cases without reducing in any way the Renter's commitments as per this contract.
	

 	

 	

 	
 	

If differences of opinion emerge between the parties on the question whether or not a certain detail of the jobs performed is ready for delivery according to this paragraph the difference will be decided by the arbitration mechanism established in
paragraph 4(d) above.
	

 	

 	

(5)	
 	

The Renter's abstention from participating in the inspections and/or from editing any of the protocols for unreasonable reasons will not serve as grounds for not accepting the rented object and/or for the incompliance of any of the parties with this
contract.
	

 	

 	

(6)	
 	

Form 4 for inhabitation of the rented object will be submitted to the Renter 3 days before the delivery date, namely on the    day            , subject to the
submittal of all the required authorizations and/or licenses and/or permits, the submittal of which depends on the Renter.
	

 	

(c)	

It is agreed and declared that everything aforesaid in this paragraph, regarding the delivery dates will be postponed for the period of delay, in case of a force majeure event, which by nature is out of the control of any of the parties and which in
practice caused a delay in the project's execution including general strikes and shutdowns in Israel, unpredictable natural disasters, days recognized and/or declared by the inter-ministerial committee and/or by the qualified authorities as working
shutdown in the construction sector, strikes of the planning and building committees and/or at the local authorities and/or at other qualified authorities, long periods with no reunions of the local planning and building committee and so
forth.
	

 	

 	

It is made clear hereby that the period of delivery delay due to force majeure events will be equal to the period of time when the event actually prevents the Company from fulfilling its duties within this contract subject to the reasonable efforts
that the Company has to make to reduce the delay period.

	7.
	Tenancy Period

	(a)
	The
rented object's tenancy period, will start at the date of actual delivery and last for 10 (ten) years ("Tenancy Period").

	(b)
	The
Renter has the option of extending the tenancy period for an additional period of 5 years ("First Option Period") and for a
second period of 5 (five) years ("Second Option Period"). 

The
first and second options will hereafter be denominated together—("The Option Period"). 

Exercise
of the Renter's right to the option period is conditioned upon the existence of the following accumulative conditions: 

	(1)
	The
Renter neither violated, during the tenancy period, repeatedly and/or substantially the prescriptions of this rental agreement nor did it abstained from correcting said violations
after having received notices from the Company on the existence of the violations.

	(2)
	The
Company did not receive an early written notice in advance from the Renter at least 9 (nine) months before the end of the tenancy period and/or the option period saying it did not
wish to exercise its right to the option period or second option period. 

12

 

Throughout
the option periods all the prescriptions of this agreement will apply with the necessary changes, except the rent, which it is agreed that will be raised at every option period, as the
Renter chooses to exercise, as per item (b) above, at a rate of 5% real increase. 

	(c)
	Beginning
on the delivery date all the Renter's duties and obligations resulting from this agreement will apply and the tenancy period will start on that date for any purpose whether
or not the Renter appeared on that date to take hold of the rented object.

	(d)
	The
Renter will be entitled to notify the Company on an early finalization of the rented object's tenancy period, at least 9 months in advance and in writing, this at the end
of the fifth year or at least 8 months in advance and in writing at the end of the eighth year of the tenancy period. 

To
avoid doubts, these exit points are the Renter's only exit points. 

In
the case that the Renter notifies the Company on the finalization of the tenancy period at the end of 5 years, the Renter will pay the Company an agreed liquidated compensation in the amount
of $1,500,000 (one and a half million US Dollars), on the date of clearing out the rented object. 

In
the case that the Renter notifies the Company on the finalization of the tenancy period at the end of 8 years, the Renter will pay the Company an agreed liquidated compensation in the amount
of $600,000 (six hundred thousand US Dollars), on the date of clearing out the rented object. 

Despite
of the above, it is agreed between the parties that in as much as the rented object is rented to an alternative renter, as per paragraph 16 c hereinafter, it will not be considered as
an early finalization of the tenancy period and the Renter will not be compelled to pay the Company the above agreed compensation. 

	8.
	The Rent

	(a)
	In
return for the building's rental the Renter will pay the Company throughout the tenancy period and due to it, a monthly rent in the amount of NIS 411,642 (at a rate of US$11 per 1
sq.m. of the building's area), with the addition of the legal AVT. 

In
return for the rental of the parking lot the Renter will pay the Company throughout the tenancy period and due to it, a monthly rent in the amount of NIS 8,019 (at a rate of US$18 per 1 parking
isle), with the addition of the legal AVT. To avoid doubts, it is made clear that the Renter will not pay rent or any other fee for the dedicated parking spaces in addition to the rent paid by it and
the rent paid for the building rental will be considered as paid for the dedicated parking spaces too. 

	(b)
	It
is agreed that the Renter will pay the Company the rent for the first three rental months plus legal AVT amounting to NIS 1,444,863 ($324,324) on the occasion of signing this
agreement and as a condition for it. In the case of cancellation of this agreement according to paragraph 6(a((2) above, the rent mentioned in this paragraph will be reimbursed the Renter with
the addition of linkage differentials.

	(c)
	By
means of the rent the Renter acquires the right of reasonable utilization of the infrastructure available at the Center including: roads, sidewalks, gardens, illumination,
signboards, parking (subject to paragraph 12 hereinafter), fences, sewage and water lines. Also, the Renter's employees any everyone coming on its behalf have the right to enter the Center's
grounds and or the rented object, free of charge. 

13

 

	(d)
	The
rent will be payable by the Renter on the first day of each month, for the current month, against a legal invoice issued by the Company to the renter. The rent will bear linkage
to the consumer's price index as detailed hereinafter.

	(e)
	The
rent will be linked to the consumer's price index as follows:

	(1)
	If
on any actual payment day of the rent (or part of it) it comes out that the new index (as defined hereinafter) on the said day of making the payment went up in relation to the
basic index (as defined hereunder) the Renter will pay the Company said payment increased proportionally to the rate of increase of the new index relatively to the basic index.

	(2)
	"The Basic Index"—The consumer's price index of December 2004 published on the 15th of
January 2005 and stood at            points.

	(3)
	"The New Index"—The last consumer's price index known at the time of the actual payment of each and every rent payment or
part of it.

	(4)
	In
the case that the index is cancelled or not published any more for whatever reason the Company will act according to the usual commercial practice prevailing in the country.

	(f)
	Any
sum that the Renter is due to pay the Company by this agreement that the Renter does not pay on time, will bear interest at a rate equal to the rate applied by Bank Leumi
Le-Israel Ltd. on unauthorized overdrafts, from the date set for the payment according to this agreement until its actual payment.

	(g)
	It
is hereby agreed and the Renter undertakes that all the payments that it is obliged to pay the Company according to the prescriptions of this agreement will be paid to the Company
by means of check or bank transfer to the Company's account the details of which follow: account nr. 485100/94 at the Leumi Bank Main Haifa Branch (876).

	9.
	Rendering Services at the Center

	(a)
	The
signing by the Renter of this contract will constitute and will be considered as its signing the contract enclosed hereto as Annex "F", between MATA"M and the occupants of the
Center (as defined above) regarding the Center's Service Company SHATA'M Haifa Ltd. ("SAHATA"M") and the alterations in said contract that are concluded between the Renter, MATA"M and SHATA"M
from time to time will apply also to the rented object, object of this contract. This paragraph will be considered as a contract also in favor of a third party.

	(b)
	In
addition to the rent and the other payments obliging the Renter as established above and hereinafter in this agreement the Renter will pay SHATA"M from the date of delivery its
share of the payments in the amount set from time to time and applicable to the Center tenants including the participation fee for the Center's services according to SHATA"M's charges, and/or whoever
replaces it, as set from time to time by SHATA"M and at the times set by it from time to time, all according to the conditions and prescriptions of the contract Annex "F".

	(c)
	With
no limitation of the aforesaid, the Renter declares that it is known to it that SHATA"M will render the Renter optional services as defined in the contract Annex "F", among which
there is the supply of cold and hot water up to the buildings boundary for the air-conditioning systems installed therein. The Renter undertakes paying, subject to the fulfillment of
SHATA"M's essential obligations toward it under said contract, its share in the payments as set from time to time and which are applicable to the Center's tenants according to SHATA"M's charges for
those services. 

14

  

	(d)
	The
Renter declares that the responsibility for rendering the services at the Center is in the hands of the service company, namely SHATA"M and/or any entity that replaces it and that
MATA"M and also/or the Gev-Yam Le-Karkaot Company Ltd. and also/or the Haifa Economic Corporation Ltd. Will not be responsible for the supply of services at the
Center and the Renter does not and will not have any complaints and/or demands and/or claims against MATA"M and/or the Gev-Yam Le-Karkaot Company Ltd. and/or the Haifa
Economic Corporation Ltd. For any failure, disturbance, inconvenience or expense to the Renter caused by the lack of services and/or faulty services mentioned above and/or part of them, all
subject to the liability applicable by law to any of the above.

	(e)
	The
Company declares that a paragraph similar to this paragraph 9 exists in all the rental agreements between the Company and the companies renting areas at the Center, and
that no change has been introduced to the agreement Annex "F" with any of the renters at the Center.

	10.
	Taxes, Levies and Compulsory Payments

During
the tenancy period and due to it the Renter will pay in addition to the rent as detailed in paragraph 8of this contract, also the taxes and the payments detailed hereunder: 

	(a)
	All
the taxes, the fees, the levies and other payments of any sort and kind charged and/or that will be charged on the rented object's tenants and/or on the business done at the
rented object and/or on the parking facility at the Renter's disposal according to this agreement, as much as charged, including business tax, signboards tax. 

In
the case that in the course of the tenancy due to legislation changes a property tax is charged on land owners instead of being charged on land holders, and as result MATA"M is compelled to bear
this expense, it is agreed that the rent that the Renter has to pay MATA"M by this contract will be augmented by the rate of the property tax that MATA"M is required to pay for the rented object. 

	(b)
	All
the payments for maintenance and consumption of electricity, water, telephone and any other expense related to the use and operation of the rented object. The Renter will contact
directly these institutions, will take care of signing supply contracts with them and will pay the debit bills at the times set for that. 

The
Renter declares that it will contact the Israel Electric Corporation directly in order to supply power to the rented object by a high voltage accumulator and its transformation to low voltage. 

	(c)
	It
is known to and agreed by the Renter that added value tax applicable and/or that will be applicable to the Renter's payments as result of this contract as they are from time to
time is not included in the rent and it will be charged on the Renter and will be paid by the Renter at the time of its payment by MATA"M to the authorities against an appropriate tax invoice.

	(d)
	The
Renter undertakes to keep according to the law and present from time to time upon request all the receipts or certificates proving that it has paid all the payments it is obliged
by this paragraph to pay the authorities and/or the different entities.

	11.
	Rental Objective

Subject
to the prescriptions of this contract, the building us being rented to the Renter the Renter's enterprise and its business activity, all subject to the relevant Cities Building Plan existing
at the time of the signing of this contract by the parties ("Rental Objective"). The Renter declares and undertakes hereby that it will not make use of
the rented object for another purpose but for the rental objective unless it receives MATA"M's written approval in advance for that purpose.] 

15

 
	12.
	Parking

	(a)
	The
Renter and/or its employees and/or its guests will be entitled to random and free of charge use of the parking spaces at the Center as long as those are not assigned in the
present or in the future by the Company and at its sole discretion, to the specific use of any third party, and/or in as much as a fee for the use of this parking spaces is not charged in the future.

	(b)
	The
prescriptions of item (a) above will not be considered as imposing any obligation on the Company to put at the Renter's disposal and/or at the disposal of its employees
and/or guests any parking space in addition to the Renter's parking space, and the Renter will not have any demands toward the Company and it will not have the possibility of using any parking space
above the its quota of parking spaces.

	(c)
	The
Company will assign for the Renter 56 dedicated parking isles next to the building (but not less than one parking isle for every gross 150 sq.m. of the rented object), at a
distance not exceeding          meters from the main entrance to the building to each parking isle (hereinafter: "The Dedicated Parking
Isles"). The Company will be entitled to change the location of those parking spaces and assign the Renter other places, at the same conditions including the distance from the
building's main entrance, to the best of its discretion.

	(d)
	In
addition to the aforesaid, the Renter rents from the Company the parking lot for the whole tenancy period. 

The
Renter will be entitled to notify the Company, 4 months in advance and in writing, its wish to decrease the number of parking spaces at the parking lot, as long as in any case the number of
parking spaces at the parking lot is not less than 74 parking spaces. 

	(e)
	At
the end of 5 years from the delivery date, the Company will be entitled to notify the Renter, 6 months in advance and in writing, on the termination of the parking
lot's rental 

In
such a case, and if the Renter so requests, the Company will rent to it up to 100 alternative parking spaces (as requested by the Renter), at an underground or upper level building, at a reasonable
distance from the building's main entrance, all as per the Company's discretion, in return for a monthly rent amounting to $60 (sixty US Dollars) for each parking space, with the addition of AVI
according to the law ("The Alternative Parking"). The alternative parking will be considered as part of the rented object for any purpose and issue,
including the issue of the Renter's obligation to bear any additional payment applicable due to holding the alternative parking, including the property tax. 

	13.
	Warranties

	(a)
	To
ensure fulfillment of each of the Renter's commitments according to this contract the Renter will submit to the Company on the occasion of signing this contract and as a condition
for signing it the following warranties:

	(1)
	A
bank guarantee for the amount of NIS 1,444,863 ($ 324,324 at the Dollar rate on the day of signing the agreement) autonomous unconditional, with the text attached to this contract
as Annex "H". The guarantees amount will be linked to the consumer's prices index beginning with the basic index (as defined above) and up to the index published recently before each and every payment
according to this guarantee. 

(Remark:
the bank guarantee's capital sum will be equivalent to 3 months rent plus AVT). 

	(2)
	A
deposit amounting to NIS 1,444,863 ($ 324,324) in the trusted hands of Attorney S. Friedman & Co., Haifa ("The Trustee")
throughout the tenancy period. The Trustee will 

16

 

deposit
said deposit as per the Renters instructions. The Trustee will transfer to the Company the deposit money, all or part of it, in the case of a substantial violation by the Renter of the rental
agreement which has not been corrected within 7 days from the date on which the Company notifies on such violation. The fruits of the deposit, as much as there are, at the time of its return to
the Renter, will be credited in the Renter's favor. 

(Remark:
the deposit's capital sum will be equivalent to 3 months rent plus AVT). 

The
Renter will be entitled at any time to exchange the aforementioned deposit by an autonomous unconditional bank guarantee equal in amount to the deposit. The prescriptions of items (a)(1) and
(B) will apply to this paragraph above and hereinafter. 

	(b)
	It
is agreed regarding the aforementioned warranties in the above item (a) that all the following terms will apply:

	(1)
	In
the case that any sum out of those guarantees is made effective and/or set off, the Renter undertakes to deposit in the Company's hands within 7 (seven) days from the date of its
notification the sum set off and/or made effective as above.

	(2)
	The
guarantee's validity time will be one year and the Renter undertakes to extend the guarantee's validity time from time to time as long as it has not received from the Company a
confirmation stating it agrees to return the guarantee to the Renter. 

The
Renter will submit to the Company from time to time a certificate of extension of the above guarantee. 

If
the Renter does not extend the guarantee's validity as detailed above the Company will be entitled to make effective and/or set off the guarantee with no need of notification. 

	(3)
	In
the case that the Company has not set off and/or made effective any sum out of the warranties, the warranties or their balance after setting off or making effective as described
above, will be returned to the Renter, 90 days after having cleared out the rented object, subject to the fulfillment of all the Renter's obligations according to this contract.

	(c)
	In
addition to the above said guarantee, the Renter will deposit in the Company's hands, at the time of signing this agreement, the guarantee of the Zoran Corporation parent company
for the fulfillment of all the Renter's obligations according to this contract and indemnifying the Company for all the expenses and damages inflicted as result of the Renter's incompliance with this
contract with the formulation usual at the Company and attached hereto as Annex "I" to this contract.

	(d)
	The
Renter will also deposit, at the time of signing this agreement, an additional deposit amounting to NIS 1,444,863 ($ 324,324) to be deposited in the Trustee's hands, this until
the date of finishing the parallel jobs, as defined in paragraph 5 above. The additional deposit mentioned in this item will serve the Renter in financing the parallel jobs and will be released
to the Renter according to the construction advance and according to a payments spreading schedule to be agreed upon between the parties before the beginning of the parallel jobs. 

The
prescriptions of the above item (a)(2) will apply to the additional deposit of this item, subject to the necessary modifications. 

(Remark:
the additional deposit's capital sum will be equivalent to 3 months rent plus AVT). 

	(f)
	The
submittal of warranties in accordance with this paragraph does not limit any of the Renter's undertakings according to this contract and/or constitute Company's waiver of any of
its rights by this contract including any remedy acquired by this contract and by law. 

17

 

	(g)
	To
remove any doubt, the execution of the warranties and/or any part of them by the Company does not limit any of the Renter's undertakings within this contract and does not
constitute the Company's waiver of any of its rights by this contract including any remedy acquired by this contract and by law.

	14.
	Liability

	(a)
	The
Renter will be liable by law toward the Company and/or any third party as the case may be, for any harm, forfeit, damage or loss to a person or property (and without limiting the
generality of the aforesaid including the Renter's property, employees and guests), that will occur or be caused within the rented object's boundaries and/or the Center as result of a Renter's action
or omission and/or of anyone acting on its behalf and the above liability will not apply to the Company subject to the following.

	(b)
	Despite
of the aforesaid in item (a) the Renter will be liable by law for any damage of any kind caused by action and/or omission of the Renter and/or anyone working on its
behalf:

	(1)
	To
the rented object's contents introduced by the Renter and/or on its behalf;

	(2)
	To
the rented building except the risks related to the building that are covered by the insurance maintained by MATA"M as described in the Insurance Annex.

	(c)
	In
the case that a suit is filed against the Company by a third party due to a damage for which the Renter is liable by this paragraph 14 then the Renter will have to indemnify
the Company within 7 days from the date when the Company was required to pay the above sum, for any sum that the Company is compelled to pay the third party, following a tribunal's final
verdict, with the addition of all the Company's expenses incurred into because of the trial with the third party and without limiting the generality of the aforesaid, the capital, interest, linkage
differentials, attorney's fee, tolls, trial expenses, AVT and other expenses of any kind resulting from the suit. 

The
Company's indemnification by the Renter will be conditioned upon a notification on the existence of the proceedings against the Company and also upon the possibility being given the Renter to
defend itself against the claims raised within the above proceedings. 

	(d)
	The
aforesaid in this paragraph does not apply to a damage caused by a hidden defect in the rented object.

	(e)
	The
above sub-paragraphs of this paragraph are meant to be complementary of one another and not limitative of one another.

	15.
	Insurance

The
parties undertake acting according to Annex "J" to this agreement. 

	16.
	Transfer or Lien of Rights and Preservation of Rights

	(a)
	Any
kind of mortgage on the Renter's rights under the power of this contract, all or part of them, is forbidden.

	(b)
	Subject
to the prescriptions of this agreement, the Renter will not be entitled to transfer and/or endorse its rights and/or its obligations under this contract or any part of them to
other/s (either with a reward or without a reward) unless it has obtained the Company's prior authorization in writing. 

In
spite of the aforesaid in this item (b) it is agreed that the Renter will be entitled to endorse its rights under this contract to its parent company Zoran Corporation addressed at 1390
Kifer 

18

 

Road
Sunnyvale, CA 94086-5305 USA ("The Parent Company"), this subject to all the terms detail hereunder: 

	(1)
	The
Renter will notify the Company at least two months in advance and in writing on its intention to endorse its rights to the Parent Company.

	(2)
	The
Parent Company will be liable from the endorsement date for the fulfillment of all the Renter's obligations under this contract, and also for the fulfillment of all the Renter's
past undertakings if and in as much as they were not fulfilled by the Renter.

	(3)
	Without
limitation of the aforesaid in item (b)(2) it is made clear hereby that the endorsement of the Renter's rights to the Parent Company will not be construed as a limitation in
any way of the Renter's obligations under this contract until the endorsement date and/or as a limitation and/or as a waiver on the Company's side of any claim and/or right that the Company is
entitled to under this contract and/or under the law.

	(c)
	It
is hereby agreed and declared by the parties that the Renter will have the right of bringing an alternative renter as long as all the following accumulative conditions are
fulfilled:

	(1)
	The
Renter fulfills all the contract's conditions until the date of actual transfer of the rented object to the alternative renter that has been approved by the Company as described
hereunder. And also

	(2)
	The
Company receives advance written notice to that effect at least 2 (two) months in advance; and also

	(3)
	The
alternative renter has been approved by the Company the decision of which is exclusive and final although the Company will not deny its authorization but for plausible; and also

	(4)
	The
conditions of the new rental contract with the alternative renter are concluded between him and the Company to the Company's full satisfaction as long as they are not less than
the conditions of this contract (unless, as much as the conditions are lessened, the Renter bears the difference, as agreed by the parties); and also

	(5)
	subject
to the aforesaid in item (4), the alternative renter fulfills all the Renter's obligations and gives the Company warranties/guarantees to its satisfaction. 

The
aforesaid in this item does not limit the Renter's obligations and/or undertakings under this contract. 

	(d)
	The
Company is entitled to transfer and/or endorse and/or mortgage its rights and/or any part of them under this contract (including ownership of the rented object) to other(s)
without needing the Renter's permission under the condition that the Renter's rights under this contract are not harmed.

	(e)
	With
no prejudice to the generality of the aforesaid, it is agreed that the Renter will be entitled to rent the rented object and/or part of it in sub-rental to another,
subject to the fulfillment of all the conditions detailed hereunder:

	(1)
	The
details of the sub-renter are relayed by the Renter to the Company in writing at least 21 days in advance; and also

	(2)
	Following
receipt of the above details the Company, at its exclusive discretion, gives its consent to the above sub-renter. The Company undertakes not declining unless for
plausible reasons. And also 

19

 

	(3)
	The
Renter is responsible for fulfilling the obligations and undertakings under this contract and is also responsible toward the Company for any action and/or omission of any kind of
the sub-renter and the sub-rental will not subtract directly or indirectly, explicitly or implicitly [This is a legal term. I have no idea what it means but I
assume it means something like "Explicitly"] from the Renter's undertakings toward the Company under this contract; and also

	(4)
	The
Company's consent does not permit the above sub-rental to impose on the Company liability of any kind and/or to subtract from and/or prejudice in any way its rights
under this contract; and also

	(5)
	The
sub-renter will be entitled to use the area rented to him by the Renter only for a purpose that does not contradict the Cities Building Plan applicable to the rented
object.

	17.
	Set-off

The
parties will not be entitled to set-off a sum payable to them by the other party under this contract from any sum payable by them to the other party. 

	18.
	Prescriptions Regarding the Use of the Rented Object

	 	(a)	The Renter will take care that the rented object functions as customary at the Center and the Renter will obey and fulfill all the instructions given from time to time, by the Company and/or by SHATA"M regarding the
behavioral rules at the Center, subject to the instructions' plausibleness. The Renter will verify and take care that its employees and/or those coming on its behalf also behave according to the prescriptions of this paragraph.
	

 	

(b)	

(1)	
 	

The Renter will be entitled to make changes in the rented object, except for structural changes and/or changes in the external envelope of the rented object and/or changes in the electro-mechanical systems and/or changes that can deteriorate the
building's safety, which will require the Company's consent, in writing and in advance, and in accordance with the terms set by the Company. The Company will not deny changes as aforesaid but for reasonable reasons and in writing.
	

 	

 	

 	
 	

Any change made in contradiction to the prescriptions of this item, will be removed by the Renter and on its account, immediately upon receipt of the Company's requirement to do so, either during the tenancy period or thereafter. In the case that the
Company authorizes a change as aforesaid, the above changes and/or installations will remain in the Company's possession and the Renter will not be entitled to claim any compensation for them.
	

 	

 	

(2)	
 	

All the modification and/or installation jobs done in the rented object according to the aforesaid in item (b)(1), will be carried out by the Renter fully on its account and responsibility, and no responsibility whatsoever of any kind will be
attachable to the Company as a renting entity and/or as an owner.

	(c)
	The
Renter will maintain order and cleanliness in the rented object and in its surroundings and will also observe the instructions of the Company and SHATA"M regarding cleaning
procedures, the manner of getting rid of garbage residues and litter and maintaining the functionality of the building's drainage and sewage system. The omission of the abovementioned instructions
will not relieve the Renter from its undertakings under this paragraph.

	(d)
	The
Renter declares that subject to the fulfillment of the Company's undertakings needed for this purpose, it will obtain until the beginning of the tenancy period, all the permits
and licenses required in order to manage the rented object and/or for making use of the rented 

20

 

object
according to the prescriptions of this contract and the prescriptions of the law and the related regulations and will always be equipped with the corresponding valid licenses and authorizations
for every activity related to the management and/or utilization of the rented object and which needs an authorization or a license by law. 

Failure
in obtaining the abovementioned licenses and/or any part of them, as long as is not a result of a breech of commitments by the Company, will not constitute a motive for termination of this
contract and/or incompliance with the Renter's undertakings under this contract and particularly not paying the rent and other payments under this contract. 

	(e)
	The
Renter's posting signboards or other publicizing or presentation accessories on the external walls of the rented object or at the common areas in the building and in its
surroundings requires the Company's prior and written authorization. The Company will not deny consent as aforesaid unless for plausible reasons only. Any signboards as aforesaid will be according to
the common practice at the Center.

	(f)
	During
the tenancy period and after having obtained the fire fighting authorization for the rented object, the Renter will observe the Company's instructions and those of any other
qualified institution, regarding the fire fighting and fire prevention arrangements and procedures, Civil Defense, safety and security and will also acquire and/or install on its account and in
coordination with the Company in writing and in advance, according to the instructions of the above entities, all the prevention and safety equipment needed for implementing and maintaining the
aforementioned instructions. 

The
equipment will remain as the Renter's property that will be entitled to move it out from the rented object at the end of the tenancy period and will do so if the Company so requires. 

	(g)
	Disturbance, prevention of obstacles and environmental quality

	(1)
	The
Renter will manage the plant and will utilize the rented object abstaining from disturbing neighbors and abstaining from creating obstacles at the rented object or at its
surroundings all in accordance with the customs at the building and/or at the Center and /or at the Company.

	(2)
	The
Renter hereby confirms that its plant does not constitute an ecological nuisance and that it will not be such throughout the tenancy period according to this contract.

	(3)
	Without
limitation of all the aforesaid the Renter will act and take care of instructing its employees and everyone acting on its behalf according to the Nuisance Prevention Law
HaTaSHK"A-1961 and the Law for Maintaining Cleanliness VHaTaSHMa"D-1984 including all their regulations and decrees as well as all the complementary laws of the Haifa
Municipality and the Local Authority's complementary laws.

	(4)
	The
Company undertakes abstaining from creating the Renter any obstacles as aforesaid in this item. The Company also confirms that this item is included in all the rental agreements
of the other tenants at the Center.

	(h)
	The
Renter undertakes to abstain from doing or allowing other(s) to do at the rented object any deed or omission that can impose on the Company liability by law including damages to a
person and/or property. 

21

 

	(i)
	Every
time that hot jobs are carried out at the rented object and/or at its surroundings by the Renter and/or by anyone on its behalf, outside the normal course of its activity, the
Renter undertakes acting as follows:

	(1)
	Before
the execution of any hot job the person in charge or a person designated by the Renter will check the working area intended for the job and will verify that all flammable
substances have been removed out of a radius of at least 10 m.

	(2)
	Fixed
objects that can not be moved have to be covered with a non-flammable wrap.

	(3)
	Before
executing the job all openings and passages have to be blocked.

	(4)
	A
"fire scout" will be posted in the vicinity of the workers doing the "hot job" and equipped with a portable fire-extinguisher suitable for the sort of flammable
materials in the area, and that will be his only task.

	19.
	Responsibility for the Quality of the Buildings and the Rented Object

	(a)
	Without
limiting the Renter's responsibility as detailed above and hereinafter in this agreement, the Company will be responsible according to the Sale Act (Apartments)
HaTaSHLa"G-1973 ("Sale Act") to repair the defects and/or deficiencies and/or incompatibilities (hereinafter together:
"Defect" and/or "Defects") that will be detected and/or will be created in the building during the
periods of time established in the Sale Act ("Guarantee Period"). The Renter has to notify the Company in writing on any defect as aforesaid immediately
upon being detected. If the Renter does not notify the Company of defects within a reasonable period of time from the detection, it will be considered as a Renter's confirmation that there are no
defects in the rented object as aforesaid. 

Immediately
after receiving a notification from the Renter as aforesaid the Company will do the best it can to fully apply the contractor's commitment toward the Company as described in this item (a).
If the contractor does not repair whatever needs be repaired within the contractor's guarantee then the Company will take care of repairing on its account said defects and/or breakdown within a
reasonable period of time according to the type of damage. 

	(b)
	Without
subtracting from the aforesaid, if the Renter notifies the Company after the expiration of the guarantee period of a defect for which there is from the contractor that did the
job at the rented object a guarantee for a period longer than the guarantee period as defined in item (a) above then the Company will apply its right under said guarantee so that the contractor
repairs the defect and that without recognizing any obligation and/or responsibility on its side.

	(c)
	In
addition to the aforesaid in item s (a) and (b) above and without subtracting from it, it is agreed that subject to the Renter's fulfillment of its undertakings
mentioned hereinafter in items (e) and (f) and without prejudice to the Renter's responsibility as detailed above and herein after in this agreement, the Company will be responsible,
throughout the tenancy period, for repairing deficiencies and/or defects that are detected, if detected, in the structure of the rented object (including the roof of the rented object) and in the
external walls of the rented object and also sealing defects as long as they have not been caused and/or occurred under the Renter's responsibility as established in this contract and/or by law in the
rented object throughout the tenancy period. 

The
Company undertakes repairing on its account, any defect, breakdown, wear or damage (that are within the Company's responsibility under this contract, and without prejudice of the Renter's
responsibility under this contract), created in the rented object, in the accessories, in the installations and in the equipment ("The Damages") and
that within a reasonable period of time according to the type of defect, breakdown or damage. 

22

 

If
the Company does not repair the damages as aforesaid within a reasonable period of time according to the type of damage/s then the Renter will be entitled (but not obliged) subject to a written
notice 7 days in advance to carry out the repair jobs instead of the Company and on its own account and the Company will obliged to reimburse any expense incurred in by the Renter due to the
damages with the addition of 10% as management expenses and this within 10 (ten) days from the day of the Renter's first demand and all that without prejudice of the remedies imparted the Renter under
this contract or by law. 

	(d)
	Other
than the aforesaid, no other obligation and/or responsibility will be applicable to the Company due to defects of any kind in the rented object.

	(e)
	Beginning
on the delivery date, and subject to the existence of defects, deficiencies or incompatibilities the responsibility for which belongs to the Company as detailed above, the
Renter will be responsible, on its account, for the current maintenance of the rented object, its systems, including the maintenance of the air-conditioning systems, the electrical system,
elevators, building's roof, hygiene and sewage pipe-works, gardens, parking lots, cleaning and maintaining the rented object, etc., including the engagement of relevant suppliers and/or
contractors. 

The
Company will not responsible for the rented object's maintenance during the tenancy period, without prejudice of the Company's responsibility for repairing defects as detailed above in this
contract. 

	(f)
	The
Renter undertakes repairing on its account, any defect, breakdown, wear or damage (that is not within the Company's responsibility according to the prescriptions of this
contract), created in the rented object, in the accessories, in the installations and in the equipment therein ("The Damages") and this within a
reasonable period of time according to the type of defect, breakdown or damage, whether the damages have been caused to the rented object or they cause disturbance and/or obstacles and or damages to
the Center. 

It
is agreed that the aforesaid in items (e) and (f) is not applicable to the air-conditioning systems serving the building as far as those are located outside the envelope
and boundaries of the building which will be maintained by the Center's Service Company—the SHATA"M Company. 

If
the Renter does not repair the damages as aforesaid within a reasonable period of time according to the type of damage/s then the Company will be entitled (but not obliged) subject to a written
notice 7 days in advance to enter the rented object and carry out the maintenance and repair jobs instead of the Renter and on its own account and the Renter will obliged to reimburse any
expense incurred in by the Company due to the damages with the addition of 10% as management expenses and this within 10 (ten) days from the day of the Company's first demand and all that without
prejudice of the remedies imparted the Company under this contract or by law. 

	(g)
	It
is hereby agreed that if the Renter does not reimburse the Company the sums spent on the repair of the damages, within 10 (ten) days from the day of notification, a delay interest
will be added to those sums and this from the date when the Renter was due to reimburse the sums until their actual payment to the Company.

	20.
	Inapplicability of Tenants Protection Laws

The
parties hereby declare that: 

	(a)
	The
construction of the building and the rented object was completed after TaSHKa"H-1968 and the Tenants Protection Law [combined version],
HaTaSHLa"B-1972 does not apply to the rental under this contract, or at all. 

23

 

	(b)
	No
"key-fee" or another similar payment for the utilization of the rented object and what is related to it has been paid nor will be paid the Company, or any other person,
has been received nor will be received from the Renter.

	(c)
	The
Tenant Law [combined version], HaTaSHLa"B-1972 and/or any other law for the protection of tenants that exists in the present or that is
legislated in the future will not be applicable due to this contract and to the consequent relationship between the parties.

	21.
	The Right to Enter the Rented Object

The
Company's representatives will have the right to enter the rented object (subject to security limitations) at reasonable hours and pending prior coordination with the Renter in order to assess the
level of compliance with the prescriptions of this contract and/or to show the rented object to others and/or to take the actions and measures established in this contract or by law and which require
entering the rented object, under the condition that any damage inflicted on the Renter as result of its refusal to enable entrance in the cases and for the purposes stated above, or its abstention
from coordinating the entrance to the rented object as aforesaid will be of the Renter's sole responsibility, and the Renter will have no complaint and/or demand against the Company due to that. 

The
Company will invest best effort to cause that the disturbance to the Renter is as reduced as possible and that the conditions of the rented object are returned to their original state as soon as
possible and as far as feasible. 

	22.
	Evacuation of the Rented Object

	(a)
	Not
later than the expiration day of the tenancy period the Renter will clear out the rented object and will return tenure to the Company, free of any person and object (except the
equipment and accessories belonging to the Company) and in good order and condition as was delivered to the Renter, except for reasonable wear.

	(b)
	Due
to and for each day of delay in returning tenure of the rented object in contradiction with the aforesaid in item (a) above, the Renter will pay the Company rent for the
whole month and the last of the tenancy period divided by the number 15 (fifteen) plus AVT by law. This payment that will be considered as a liquidated damages agreed in advance will not subtract from
any other remedy the Company is entitled to by law and/or contract.

	(c)
	At
the time of clearing out the representatives of the Company's and the Renter will edit a clear-out protocol where the deficiencies and the repairs that the Renter has
to carry out in order to return the rented object in god order and condition and on time as agreed. 

Inspite
of the aforesaid, the Company will be entitled to carry out the repairs on its own and the Renter will reinburse the Company its reasonable expenses due to the repairs as per the invoices
submitted to the Renter by MATA"M. MATA"M will be entitled to retain the warranties dealt with in paragraph 10 until the completion of the repair jobs done by the Company and if necessary, the
Company is entitled to make the warranties effective to cover its reasonable expenses as mentioned above. 

	23.
	Representation Denial, the Renter's Employees

	(a)
	Nothing
that has been said in this contract and/or the behavior of the parties under this contract, will be construed as qualifying one party to appear in name or on behalf of the
other party, or as assigning the satatus of the other party's representative.

	(b)
	The
employees of one party will not be considered employees of the other party under any citcumstance and for any purpose. 

24

 

	24.
	Substantial Violation of the Contract

Without
subtracting from the prescriptions of the law, each one of the following actions or omissions will be considered a substantial violation of the contract by the Renter and will constitute a
motive for immediate evacuation of the rented object and its return to the exclusive possession of the Company all following a written notification 21 days in advance unless the contract's
substantial violation is repaired by the Renter to the Company's satisfaction until the time set in said notification: 

	(a)
	Discontinuation
of the Renter's activity for a period longer than 180 (one hundred and eighty) days except for force majeure only and/or, filing of an application for liquidation and
the nomination of an official receiver on a fundamental part of the Renter's assets and the application or nomination, respectively, have not been cancelled within 120 days.

	(b)
	Delay
in paying the rent including the complementary rent or in one of the other payments applicable to the Renter under this contract and/or its violation for a period longer than 30
(thirty) days from the date set for their payment as long as a notification was delivered to the Renter demanding the payments and the Renter did not comply within 7 (seven) days.

	(c)
	The
transfer of the right to use or transfer or mortgage of rights or any part of them against the prescriptions of paragraph 14 above.

	(d)
	Incompliance
by the Renter with its obligation to acquire insurance according to the prescriptions of the Insurance annex.

	(e)
	Not
returning tenure of the rented object on time and in the conditions detailed in this contract.

	(f)
	Issuance
of a decree regarding the Renter that contains an arrangement with the creditors and/or an arrangement in favor of creditors and/or receivership and/or bancrupcy and/or
liquidation of any kind and/or closure of business in any way and the decree has not been cancelled in 60 days.

	(g)
	Cancelled.

	(h)
	Introduction
of changes in the rented object that require early consent from the Company without obtaining consent in advance and in writing from the Company.

	(i)
	Incompliance
with the undertaking of using the rented object for the purpose defined in this contract. 

This
paragraph is not meant to prejudice the right of the Company to receive any other remedy that the Company is entitled to against the Renter by law and/or under this contract due to its violation. 

	25.
	Early Evacuation or Abandonment

In
any case of clearing out or abandoning the rented object by the Renter before the end of the tenancy period or violation contract without the Company's written consent in advance, the Renter will
continue paying rent to the Company as well as all other payments applicable to the Renter under this contract until the end of the tenancy period as if it kept holding and using the rented object,
subject to the Company's obligation by law to reduce its losses. The prescriptions of this paragraph do not subtract from the Company's right to terminate the contract based on the aforesaid in
paragraph 24 above. 

It
is agreed and declared by the parties that this paragraph will not apply in case of force majeure (as defined hereinafter) that causes damage to the rented building such that prevents the 

25

 

possibility
of using the rented object for the rental objective during a period of 6 (six) continuous months. 

	26.
	Construction, Repairs, Improvements and Development Jobs

Nothing
that has been said in this contract will prevent MATA"M from installing facilities, building, repairing, improving and conducting development and construction jobs at the Center, except for
the rented object, as long as it does not cause unreasonable disturbance to the Renter's plant. The Renter will not oppose to the above activities and will cooperate with the Company and/or with
SHATA"M as aforesaid and on their account in anything related to their execution. 

It
is agreed that the above mentioned jobs will be under the responsibility of the Company and on its account unless the parties agree otherwise in writing. 

	27.
	Evidence and Amendment of the Contract

	(a)
	Any
modification and/or addition to this contract will only be done in an explicit written document and with the signatures of the parties to this agreement.

	(b)
	The
consent of a party to this agreement to deviate from its terms in a specific case or in a series of cases, will not constitute precedent and no analogy will be derived for the
same case and/or for any other case in the future.

	(c)
	In
the case that a party to this agreement does not apply, or is delayed in applying any of his rights imparted to him by this agreement, in a case or in a series of cases, it will
not be seen as a waiver of any of his rights.

	(d)
	It
is agreed by the parties that the receipt of a check or notes is not considered a payment until they are actually made effective.

	28.
	Jurisdiction

It
is agreed by the parties that any dispute and/or disagreement and/or judicial proceeding concerning this agreement and the consequent obligations will be decided and construed uniquely and
exclusively by the Israeli Law and that the unique and exclusive venue is the Authorized Court in Haifa. 

	29.
	Stamp Duty

	(a)
	The
stamping expenses of this agreement will be on the parties in equal shares.

	(b)
	The
stamp duty applicable to the aforementioned warranties (including the expenses for obtaining them) will be paid by the Renter.

	30.
	Secrecy (confidentiality) 

Throughout
the validity time of the contract the parties undertake maintaining in secret all the drawings pertaining to the building, the storey and the systems, with the aim of preventing malicious
sabotage in the building. 

In
any case that such disclosure is imperative the parties undertake obtaining from the receptor of the drawings a written commitment to maintain their secrecy and return them upon conclusion of the
necessity of keeping them. 

The
parties also undertake to keep in secret the contract's terms except for commercial details as much as it is necessary by the external entity/ies or by the Renter's activity. 

26

 

	31.
	Expansion of the Building

	(a)
	It
is hereby agreed that within 9 months from the date of signing this agreement, namely until the          day
                , the Renter will have the right to request the construction of an additional office floor (sixth floor), with an area of 1,600 sq.m, according to
the
preliminary design. The Renter's request will be in writing.

	(b)
	If
the Renter requests the construction of the additional floor within 3 months from the date of signing this agreement, there will be no delay in the contractual delivery
date. 

If
the Renter requests the construction of the additional floor within 3-6 months after signing this agreement, there will be a month delay in the delivery date, both the actual and
the contractual. 

If
the Renter requests the construction of the additional floor within 6-9 months after signing this agreement, there will be a two and a half months delay in the delivery of the
rented object to the Renter, both the actual and the contractual. In such a case MATA"M will be entitled to inform the Renter on the advance of the delivery date by one and a half month (namely, a
delay of one month only), and this as soon as possible after the early delivery date to MATA"M becomes known and in any case not later than 3 months before the early delivery date. 

	(c)
	On
the actual delivery date, and as a condition for it, the Renter will increase its warranties detailed in the above paragraph 13 of this agreement and also the rent payable
in advance as per the above paragraph 8(c) of this agreement and also it will be entitled to an increase in the dedicated parking spaces proportionally to the increase in the building's area.

	(d)
	The
additional floor will be added to the rented area and all the prescriptions of this agreement will apply to it for any purpose and issue.

	(e)
	The
Company declares that there is the possibility of constructing an additional building at the empty area of about 2 dunams (approx. 0.5
acres) located on the east side of the planned building, as long as the additional building is a 5 storey house and with an area of at least 5,000 sq.m. The Renter is granted
the option, throughout the tenancy period, of causing the additional building to be constructed by the Company as long as at least 5,000 sq.m of the additional building are added to the rented object
(hereinafter: "The Option").

	(f)
	The
Company undertakes abstaining from building on the area mentioned above in this item during a period of two years from signing this contract, unless for the purpose of
constructing the additional building, as aforesaid. After the two years period, the Company will be entitled to construct the additional building and the Renter will be granted the right of first
refusal to rent areas at the additional building in the terms proposed by the Company to any third party. If the Renter refuses, the Company will not be entitled to rent areas at the additional
building in terms inferior to the terms proposed by the Company to the Renter, but only after it proposed these inferior terms to the Renter. 

It
is agreed, that if the Renter requests the materialization of the expansion as aforesaid in this paragraph (f), the Renter will apply in writing to the Company, and the Company will inform
the Renter, within reasonable time, whether there exist building rights at the Center with a capacity that permits the requested expansion. Whenever the Company intends to use building rights in a
manner that jeopardizes the aforesaid expansion possibilities, the Company will inform so the Renter in writing and in advance, and will grant the Renter the opportunity of applying its right to
construct the additional building as described above. 

If
the Renter realizes the option, and subject to circumstances out of the Company's control, a contract is signed between the parties where the reward and the terms are stipulated as 

27

 

agreed
by the parties, and which will be established by the same commercial terms usual in the construction of buildings at the same time at the Center, subject to external circumstances, including
economic, business and commercial circumstances. 

	32.
	Notifications and Warning

	(a)
	Every
notification and/or warning and/or requirement sent from one party to the other in relation with this contract will be sent by special delivery mail, or handed over personally,
by means of the parties' addresses detailed hereunder (or any other address on which a notification is delivered in writing), and the aforesaid notification or warning will be considered as delivered
to the addressee upon its actual delivery—whether deliver personally or sent by the Israeli Mail—seventy two (72) hours after having been placed at the mail box with the
mail fee fully paid in advance.

	(c)
	The
aforesaid parties' addresses are—

	(1)
	The
Company—24 Ha-parsim Str., Haifa.

	(2)
	The
Renter—at the rented object.

	33.
	The
parties declare and confirm that they have read the agreement including all its paragraphs and annexes and have understood its contents, nature and significance and agree to the
stipulated therein.

	34.
	List of Annexes to the Agreement

	 	"A"	 	—	 	The Technical Specification
	 	"B"	 	—	 	The Conceptual Design
	 	"C"	 	—	 	The Detailed Design (to be enclosed after its approval)
	 	"D"	 	—	 	Quadruple Contract
	 	"E"	 	—	 	Delivery Protocol (to be enclosed after being edited)
	 	"F"	 	—	 	SHATA"M Agreement
	 	"G"	 	—	 	Void.
	 	"H"	 	—	 	Bank Guarantee Formula.
	 	"H/1"	 	—	 	Bank Guarantee Formula for Modifications and Additions
	 	"I"	 	—	 	Formula of Parent Company Warranty
	 	"J"	 	—	 	Insurance Annex
	 	"K"	 	—	 	Parking and Building Location Plan

28

 
And in Witness the Parties Sign:  

	

 	
 	

 
	
	 	

	THE COMPANY	 	THE RENTER

29

 
 

ANNEX A    
    
    TECHNICAL SPECIFICATIONS—ZORAN—WRAPAROUND WORKS    
    

Industrial
edifice construction in conformance with Israeli Standards and in accordance with the requirements, regulations and provisions of the Israeli competent authorities. 

	1.
	Location:  

The
site is located in the MATAM Park south eastern area, as per the attached drawing. 

	2.
	Edifice Description:  

The
overall edifice area is some 8,000 square meters, in 5 floors, with a an area of some 6,000 m2 each. 

The
rented premises shall be handed over to the Tenant in a wraparound finish level and the public areas, including supplies and main structures to be connected from the
relevant supplier's structures (the Electric Corporation, Bezeq, municipalities, energy center, and such). 

From
the building exterior through the extremity of each and every floor core, and thus in conformance with the following specifications: 

	a.
	The
wraparound finish standard shall be of granite integrated precast (prefabricated) units, aluminum profiles glass combined screening walls, and fixed / opening windows. 

The
external part of the entire edifice wraparound shall be performed in a comprehensive mode. The screening walls shall be performed in a complete manner, including insulation and gypsum internal
coating, upon request. The windows shall be performed completely. The outside walls (precast) shall be performed as a whole in their exterior, except for the walls interior whitewashing; 

	b.
	Upon
request, the edifice roof shall be performed with thermal insulation, acoustics and sealing;

	c.
	Main
edifice entrance lobby, complete including automatic main door (excluding counter);

	d.
	Stairwells
complete;

	e.
	Three
(3) elevators) for 13 passengers, complete according to sizes and loads required, and at a finish and high quality level, for 1.0 ton load. (One elevator for 1.5 ton
load);

	f.
	Vacant
vertical passages all along the edifice height (between the ground floor and the edifice roof), upon request. The passages shall be accessible from each and every floor. Upon
all the installations terminations, the walls shall be sealed as required, using a fireproof product, in conformance with the firefighting authorities' requirements;

	g.
	All
supplies and main structures, including high / deep voltage power supply, firefighting systems, drainage, sewage, water and hot and cold water supply to air conditioning system
shall be compatible with the Tenant's requirements and meet the relevant Israeli Standard. The above- mentioned supplies and structures shall be provided up to the floor core extremity. Hot and cold
water vertical piping system compatible to the pips 4 method, and vertical conduits for fresh air at the central shafts are included in this job;

	h.
	The
public areas, including the stairwells, shelters (completed subject to the Rear Area Headquarters' directives), main lobby, toilet rooms, technical rooms and technical spaces, to
meet requirements, shall be performed in a complete manner, and shall be installed with electrical systems, lighting, fireproof doors, fan and coil units in the main lobby, and firefighting systems
(including sprinklers), finishing and various finish works;

	i.
	Preparations
for public alarm systems, fire and smoke detection, which shall be performed from the edifice main central systems through the floor core extremity; 

 

	j.
	Complete
development works around the edifice, as per the Architect's design.

 

	3.
	Floors Details:

	a.
	Entrance, Ground floor: 

The
entrance (ground) floor shall include a 200 m2 main lobby, shelters, elevators, stairwells, shafts and toilet rooms; 

	b.
	Typical Floor: 

Shelters,
elevators, stairwells, shafts and toilet rooms; 

	c.
	Roof: 

Elevators
machine rooms and technical rooms / spaces, as per the requirements, shall be located over the roof; 

	d.
	Preparations for an additional floor: 

Gross
floor height (above the final floor surface to the bottom concrete ceiling) shall not be less than 4.00 meters. The descending beams height shall not exceed 60 cm from the ceiling bottom; in any
event, the bushing bush height shall not be less than 2.70 meters. 

Location
of the edifice foundations constructive pillars and cores shall be designed in the best possible mode in order to allow for the internal areas flexibility and maximum utilization; 

	e.
	Edifice façades: 

The
wraparound finish shall be performed using granite integrated precast elements (prefabricated)—at the basic price of US$ 25/ m2—in the minimal quantities
specified hereunder: 

	—
	about
400 m2 of opening windows (insulating glass)—one opening window for every office room;

	—
	about
900 m2 screening walls and fixed window;

	f.
	The
floors practical loads shall be as follows:

	—
	500
kg/ m2 at each floor, except for 600 kg/ m2 in a 500 m2 area at the ground floor and first floor;

	—
	the
roof floor—according to the Standard requirements and/ or the equipment loads to be defined by Tenant;

	—
	the
edifice foundations—reinforced concrete walls, pillars and beams;

	—
	the
walls—terminal blocks or reinforced concrete ceilings are designed as per the loads specified above.

 

	4.
	Public Areas—Level Finish:

	 	Main Lobby—Ground floor:
	

 	

Tiling	

:	
 	

Granite as per the Architect's selection, at basic price of US$ 25/ m2 ;
	

 	

Coating	

:	
 	

Granite as per the Architect's selection, at basic price of US$ 25/ m2 ;
	

 	

Ceiling	

:	
 	

Acoustic, made of perforated / mineral tin, as per the Architect's selection, at basic price of US$ 20/ m2 ;
	 	 	 	 	 

2

 

	

 	
Stairwells:
	

 	
The stairwells shall be coated with indigenous stones of the Rimmon type, or similar, up to 1.10 meter height, including the stair steps. Beyond the height of 1.10 m., the walls shall be Polyssid
whitewashed;
	

 	
Elevators cubicles:
	

 	

Walls	

:	
 	

Glass / mirrors / stainless steel, as per the Architect's selection;
	

 	

Floor	

:	
 	

Granite;
	

 	

Ceiling	

:	
 	

Paint coated tin, as per the Architect's selection;
	

 	
Shelters:
	

 	
Performed as per the Rear Area Headquarters' directives.
	

 	

Flooring	

:	
 	

Granite porcelain / ceramics, as per the Architect's selection, at basic price of US$ 10/ m2 ;
	

 	

Coating	

:	
 	

Granite porcelain / ceramics, as per the Architect's selection, at basic price of US$ 10/ m2, up to 2.20 m. height;
	

 	

Ceiling	

:	
 	

Tin trays, as per the Architect's selection;
	

 	

Fixed sanitary items	

:	
 	

Class A, Charsa made;
	

 	

Partitions	

:	
 	

Built with granite porcelain / ceramics / modular partitions coating;
	

 	

Surfaces	

:	
 	

Caesar stone, or similar, as per the Architect's selection;
	

 	

Doors	

:	
 	

Lintel made of galvanized tin, wooden door and Formica coating.

	5.
	Electric Systems:

	5.1
	To
complete;

	5.2
	A
150 KVA emergency generator shall be installed in the building, to service the entire building as backup for the public vital systems;

	5.3
	The
comprehensive electric works are complete up to the floors core extremities, without electricity boards in the floors and without switchers;

	5.4
	Electric
power is supplied to hired premises up to 3X250A, for every floor;

	5.5
	Firefighting
and emergency address central systems shall be installed in the building, to monitor all the structure public areas. The said central systems shall enable connection to
the Tenant's internal systems. The works are inclusive up to the floors core extremities. The Tenant shall perform, at his cost and under his responsibility, the connections between the central public
systems and his own internal system (smoke detector and address system);

	5.6
	An
area shall be allotted to UPS (without instrumentation, partition, cables and boards);

	5.7
	The
earth connections shall be performed, to conform with the law and the Israeli Standards;

	5.8
	Thunderbolt
protection shall be performed on the building roof, to conform with the law and the Israeli Standards;

	5.9
	Telephone
and communication structures:

	—
	Ladders
shall be performed in the main shaft, as preparation for communication cables (the latter to be performed by Tenant); 

3

 

	—
	The
edifice shall be connected to Bezeq, including main ramifications box; the preparatory piping system for each floor shall be performed up to the floor core extremity on
the floor.

 

	6.
	Air Conditioning System:

	6.1
	Energy
supply to the edifice air conditioning system shall be provided from MATAM (Energy Center) central air conditioning system. The system includes supply of cold and hot water up
to each floor core extremity, including a room for the pumps, circulation pumps, vertical piping system, fresh air unit, service blowers and vertical conduits, up to each floor core extremity. 

Every
floor air conditioning units, diffusion unit, every floor piping system and the monitoring system are excluded. Cooling supply to every floor of the premises for rent shall be up to about 100
tons of cooling supply; 

	6.2
	Cool
(at 85% efficiency level) fresh and treated (cooled or heated) air supply includes fresh air units and vertical conduits up to every floor core extremity. The fresh air supply
shall be in quantities of about 25.0 c. f. m. air per person;

	6.3
	The
central air conditioning system being sourced from the MATAM Energy Center is based on a four pipe system installation: 2 piping units for cold water and two piping units for hot
water that connect the MATAM Energy Center to the edifice. There are cold water production units at the Energy Center, to which an energy reservoir is connected. Hot water is supplied by means of hot
water boilers. The system is capable of supplying energy 365 days a year, 24 hours a day;

	6.4
	MATAM
shall provide a cold water unit on the roof; such unit shall be designated for the computer room, on an area of up to 50 m2. The cold water system shall be
performed up to the computer room extremity.

	6.5
	The
system shall be backed up by a generator and shall be compatible for 24 hours a day operation. Parallelly, the computer room shall be also connected to the Energy Center
main piping system.

 

	7.
	MATAM shall provide a main line of sprinklers in the vertical shaft, with ramification to every floor extremity point. The extremity
shall be equipped with a sluice valve. 

4

 
 

ANNEX D    
    
    QUADRILATERAL CONTRACT    
    

Entered
into and signed at:................., on...th day of month........, year 2005 

Between:

	MATAM, Haifa Industrial Data Center Ltd.
 Private Company No. 51-068740-3

("the Company")	 	 
	 	 	on the one hand
	and:
	
ZORAN Microelectronics Ltd.

Private Company No. 51-094944-9

("the Tenant")	
 	

 
	 	 	on the other hand
	 	 	 

	Between:	 	................................................................

Private Company #:................................

at:............................................................	 	 
	

(hereinafter referred to as: "the Other Contractor")
	

And:	
 	
ZORAN Microelectronics Ltd..............

Private Company #:................................

at:............................................................	
 	

 
	

(hereinafter referred to as: "the Tenant")
	 	 	 	 	 

	Whereas	 	on the date...................., a Contrat was signed between the Orderer and the Contractor (hereinafter the said Contract,
complete with all its documents and annexes, shall be referred to as: "the Main Contract"), relating to the performing Works for the erection of an edifice
building for rentals (hereinafter referred to as: "Premises for Rent"), as defined under the provisions of the Main Contract;
	

and whereas	
 	

the Contractor has yet to complete his Work in conformance with the Main Contract and he has not yet
delivered it to the Orderer's to his satisfaction and he is still working at the Works site;
	

and whereas	
 	

on the date...................., a Contrat was signed between the Orderer and the Tenant (hereinafter referred to as: "the Tenancy
Agreement"), according to which the Tenant shall rent the Premises for Rent which erection Works are being performed by the Contractor on behalf of the Orderer in conformance with the Main
Contract;
	

and whereas	
 	

in conformance with the Tenancy Agreement, the Tenant is entitled to perform compatibility Works in the
Premises for Rent, with the Orderer's approval, subject to a Quadrilateral Contract being signed between the Tenant, the Contractor on his behalf (hereinafter referred to as: "the Other Contractor"), the Contractor
and the Orderer;
	

and whereas	
 	

on the date...................., the Orderer confirmed performance of the Tenant's Works, as specified
hereinafter;
	

and whereas	
 	

the Tenant entered a contract with the Other Contractor for performing the said Works;
	

and whereas	
 	

on the date...................., the Agreement was signed between the Tenant and the Other Contractor (hereinafter referred to as: "the Subcontract") for performing the Works within the Premises for Rent (hereinabove and hereinafter referred to as: "the
Work" or "the Works");
	 	 	 

 

	

and whereas	
 	

according to the provisions and general and/ or specific terms and conditions of the Main Contract, the Subcontract and the Tenancy
Agreement, the Contractor and the Tenant and the Other Contractor have undertaken to
sign a Quadrilateral Contract with the Orderer;
	

and whereas	
 	

the Parties wish to enter a mutual Agreement in conformance with this Contract, all under the terms and conditions specified hereinafter;

THEREFORE, THE PARTIES HAVE AGREED, STIPULATED AND DECLARED AS FOLLOWS:  

	1.
	The preamble in this Quadrilateral Contract constitutes an integral part thereof.

	2.
	The Other Contractor's Obligations:

	2.1
	The  Other Contractor is under the obligation to perform the Work without causing the
 Contractor any delay whatsoever in performing his Works and his obligations under the provisions of the  Main
Contract subject to the confirmations he shall receive from the Superintendant, and he is under the obligation to comply to all the  Contractor's instructions in this respect and
in the matter of safety protection rules. The Supervisor shall arbitrate in the event that the  Contractor's instructions do not concern these matters. The Contractor is under the obligation to avoid
causing interferences to other contractors working at the building or its surroundings, all in compliance with the Supervisor's instructions;

	2.2
	Without
derogating from the generalities stated hereinabove, and before performing the Works and at each stage thereof, the  Other Contractor shall be under the
obligation to coordinate performance timing and mode with the  Contractor;

	2.3
	The
Other Contractor is under the obligation to use the access roads in compliance with the Superintendant's instructions;

	2.4
	The  Other Contractor is under the obligation not to use the elevator for the purpose of conveying loads;

	2.5
	The
Other Contractor is under the obligation to pay to the Contractor, as specified
under the provisions of Clause 11 hereinafter;

	2.6
	The
Other Contractor is under the obligation to terminate the entire Works to the
satisfaction of both Tenant and Orderer, and thus not later than on....................... (date) or
before, as specified under the provisions of the Subcontract;

	2.7
	Without
derogating from the generalities stated hereinabove and hereinafter, it is stressed that both the Contractor and the  Other Contractor are under the
obligation to work together and with the Tenant and the  Orderer, with the view to complete the Work within
the performance period, excellent quality and within
the budgetary framework and at the Contract fee and without causing any delay whatsoever to the the Contractor's  Works under the provisions of the
Main Contract.

	3.
	The Contractor's Obligations:

	3.1
	The
Contractor is under the obligation not to interfere with the additional Works
performance, to cooperate with the Tenant and with the Other Contractor, and to allow them to enter the  Premises for performing their Work without prejudice to his own timetable;

	3.2
	The
Contractor's main obligations under the provisions of this Contract are as follows:

	3.2.1
	Coordinate
working performance dates with the Other Contractor and enable him to perform the  Works, subject to the provisions of both the Tenancy Agreement and all the Annexes thereto and the
present contract. To avoid and and all doubt, "coordination of Works" as 

2

 

stated
hereinabove shall only and solely mean the Contractor's approving the Other contractor's request
to enter the Premises for performing the Works; 

	3.2.2
	Supply
to the Other Contractor containers for waste removal throughout his performance of the  Works. The Main Contractor is under the obligation to remove the waste from the building site to
authorized waste disposal sites;

	3.2.3
	Provide
water and power to the Other Contractor, at his request;

	3.2.4
	Appoint
a Foreman, in compliance with the 1988 Rules of Safety at Work (Construction and Building) until..................... (date), thus without derogating from the  Orderer's obligations under the provisions
of the Tenancy Agreement;

	3.2.5
	Provide
Insurance as stated under the provisions of Clause 11 hereinafter;

	3.2.6
	Determine
the regulations, if necessary, for the necessity to implement permanent and neat access roads for the various equipment and materials, for performing the  Works;

	3.2.7
	Arrange
for protection services at the work site.

 

	4.
	The Tenant's Obligations:

Tenant is hereby under the obligation to pay to the Contractor the nominal consideration stated under
Clause 7 hereinafter. 

	5.
	The Other Contractor's Fee:

The
"Contract Fee" as defined under the Subcontract terms shall be paid to the Other Contractor, in
compliance with the Subcontract terms. 

	6.
	Sureties:

It
is hereby agreed that the sureties to be provided by the Other Contractor under the Subcontract
terms, including the Performance Bond, the Lien Bond, the Advance Payment Warranty and the Bank Guarantee shall be issued to the Orderer and the  Tenant and
they shall be established to the name and benefit of the Orderer and the  Tenant. 

	7.
	The Consideration:

	7.1
	In
consideration of the Contractor's obligation performance and for his services to the Other
Contractor under the provisions of this Quadrilateral Contract the contractor shall be entitled to receive from the  Tenant, as
consideration, an amount in Shekels that shall be equal on the payment due date thereof to 3% (three percent) of the total amount of Approved
Invoices payable by the Tenant to the Other Contractor. The said consideration shall be paid to the  Contractor every month, in conformance with the previous month Approved Invoices, thus beginning on the date the
Premises are made available to the Tenant through the date of completion of the  Works in the Premises, as per the Superintendent's final and unequivocal decision;

	7.2
	The
above-mentioned consideration shall be paid to the Contractor not later than on the third day of every Gregorian calendar month
when the Works were performed.

	8.
	Additional Works:

To
avoid any and all doubt, it is hereby clarified that the Tenant is under the obligation to perform, among others through the  Other Contractor, various
additional Works at the work site throughout the  Contractor"s performance period, such as: furniture, equipment, finish on the floors designated for
offices and various additional works (hereinafter
referred to as: "the Additional Works"). 

3

 

The
Contractor shall not interfere with the Additional Works performance, he shall work in cooperation
with them, allow them to enter and operate at the site without prejudice to his own timetable. The Contractor shall inform the  Tenant of every incident on
the Other Contractor's part that might prejudice the  Contractor's own performance schedule. 

The
Contractor shall not be entitled to any additional consideration from the Orderer and/ or the  Tenant on
account of the said coordination and the integration in the timetable and Work of the  Other Contractor and/ or other contractors on the Tenant's behalf, for performing the said  Additional Works. 

	9.
	Appointment of Chief Contractor:

	9.1
	The  Contractor's obligations under the provisions of the present Contract shall not be valid unless performance of the  Works is completed. 

For
avoidance of any and all doubt, it is hereby clarified that the statements under the sub- Section hereinabove do not prejudice the obligations on the part of the  Contractor and the Orderer when implementing the obligations for the period until................
(date); 

	9.2
	Should
the contractual agreement under the provisions of the Main Contract between the  Orderer and the Contractor
become terminated due to any cause whatsoever, the provisions under this
Contract shall apply as a Tripartite Contract between the Orderer, the Tenant and the  Other Contractor, thus
without prejudice to the provisions under the Main Contract;

	9.3
	Should
the Contractor's work at the site become terminated for any cause whatsoever, the Other
Contractor and/ or an appointed contractor and/ or yet different contractor with whom a Tripartite Contract or a Quadrilateral Contract similar to the present Contract shall be
entered into, and he will perform the Works at the site, simultaneously with the Works being performed
as per the present Contract, becoming the Chief Contractor by Law, and all the statements under Clause 21 to the Main
Contract General Terms concerning the building performer and Foreman shall apply to the Other Contractor or to the Appointed
Contractor who shall become Chief Contractor. In such an instance, the Superintendent shall determine the identity of the Contractor who will become  Chief
Contractor, and his decision shall be final and absolute.

	10.
	Miscellaneous:

	10.1
	The
Parties agree that the Orderer and/ or whomever on his behalf shall be entitled at all times to issue instructions to the  Other Contractor, regarding the
Works performance mode and/ or the use of installations, and the  Other Contractor shall be under the obligation to execute the said instructions entirely,
all subject to the provisions under this Contract, the
Tenancy Agreement and Technical Annex;

	10.2
	The
Parties further agree that the Orderer and the Tenant shall be entitled, at any
time they believe, under their own sole consideration, that the Other Contractor has breached his obligations under the provisions of the  Subcontract and/
or the present Quadrilateral Contract, to instruct the Other Contractor to immediately
terminate his Work. In the event that the Other Contractor does not correct the breach within 14
(fourteen) days, the Orderer and the Tenant shall be entitled to cancel out the Quadrilateral Contract,
with the Superintendent's approval, thus by giving notice in writing to the Contractor, the Tenant, and
the Other Contractor;

	10.3
	As
from the date of cancellation notice, as stated under Clause 10.2 hereinabove, the present Quadrilateral Contract, and the  Tenant shall be entitled to choose another, new contractor who would
replace the Other Contactor who had
breached his obligations as stated. In such an instance, the Contractor shall be under the obligation to enter into another, new Quadrilateral Contract
similar to the present one, with the other, new Contractor and upon the relationship between the New Other Contractor and the  Contractor the provisions
under the Main Contract

4

 

would
apply with the call for alterations. The above statement does not prejudice the Orderer's other rights under the Tenancy
Agreement and/ or under the Law; 

	10.4
	To
avoid any and all doubt, it is hereby clarified that the Subcontract is considered as part of the present Quadrilateral Contract
inasmuch as it does not include obligations towards the Orderer and the Contractor;

	10.5
	To
avoid any and all doubt, it is hereby declared and agreed that as from the Quadrilateral Contract cancellation date by the Orderer
and the Tenant the Contractor shall not be entitled to demand from the  Orderer and/ or Tenant and/ or any other body any additional consideration whatsoever and/ or other
payment whatsoever and/ or demand expenses refund whatsoever on account of services he provided the Other Contractor with and/ or for his obligations
towards him and/ or in connection with the said site Contractor, including in connection with cancellation of the Quadrilateral Contract entered with
him and/ or regarding cancellation of the Subcontract itself;

	10.6
	To
avoid any and all doubt, Tenant hereby declares that he / she shall have no claim and/ or complaint towards the  Orderer in the event of the said
Quadrilateral Contract cancellation;

	10.7
	In
all matters concerning the relations between the Contractor, the Other Contractor,
the Tenant and the Orderer, the provisions under the bilateral contracts between them shall prevail over
the provisions of the present Contract, except for the provisions under the Quadrilateral Contract annexed to the Main Contract over which the
provisions under the present Contract shall prevail.

	11.
	Insurance:

	11.1
	14n
(fourteen) days prior to commencing performance of the Works, the Tenant is under
the obligation to deliver a written notice to the Contractor, with details of the Work, its value and
the anticipated time of completion. 

The
Contractor undertakes that from the beginning of Work and up until.............
(date—with the added maintenance period), he shall insure the Work in the framework of an All Risks Contractors Insurance
(Property + Third Party + Employers' Liability), including coverage specified under sub- Clause 11.2 hereinafter; 

	11.2
	Tenant shall undertake to update the Contractor concerning the changes applying (if
any) to the scope of Works, and the Contractor shall update the Insurers and handle issuance of the
addenda compatible with the coverage. The coverage shall include as follows:

	11.2.1
	Light
equipment and installations—US$ 50,000;

	11.2.2
	Property
in transfer and outside the yards—US$ 50,000;

	11.2.3
	Third
Party, with limited liability of not less than US$ 2,000,000 per event and lump sum for the insurance period, to include a Cross Liability Clause;

	11.2.4
	The
Tenant and/ or the Orderer and/ or the Other
Contractor and/ or the Subcontractors shall be included as the insured;

	11.3
	The
Contractor undertakes to issue the coverage documents suitable for the provisions under Clause 11 hereinabove and
hereinafter, prior to commencing the Works;

	11.4
	Should
the Tenant and/ or the Other Contractor so request, the  Contractor is under the obligation to deliver to
them a copy of the All Risks Contractors' Insurance that he has purchased, and the  Other contractor confirms and declares that up until the date of commencing the Work he shall study
thoroughly the terms and scope of the All Risks Contractors' Insurance, including procedure of completion of the Works and the conditions relating to
security at the site, and that he shall have no claim concerning the Insurance type and/ or scope. 

5

 

The
Other Contractor and the Tenant shall be entitled to purchase at their cost additional and
complementary Insurance that they deem necessary if they believe that the said additional and complementary Insurance is required. 

It
is hereby explicitly agreed that the Contractor's purchase of the All Risks Contractors' Insurance does in no way impose liability on him and/ or the  Orderer. 

The
Parties to the present Contract are under the obligation to implement all the All Risks Contractors' Insurance terms and conditions and to notify the  Contractor immediately of any event known to them
that might constitute a cause of action according to the Contractors' Insurance. The Parties also
undertake to work together as much as required for materializing an Insurance claim in the All Risks Contractors' Insurance framework. 

The  Other Contractor shall bear payment of the self- participation amounts that, according to the  Orderer's decision and upon his
determination, were not insured under the All Risks Contractors' Insurance. These amounts shall be deductible from any
amount due to the Other Contractor on account of the Works. 

In
the instance of loss and/ or damage presumably covered by the said All Risks Contractors' Insurance, the Tenant shall be under the obligation to
claim the said loss and/ or damage from the Insurers, and he / she hereby relieves the Orderer, the  Contractor and the Other
Contractor from the responsibility to pay for the loss and/ or damage at the
Insurance compensations rates that shall
actually be paid to him by the Insurers—from the date the Insurance compensations were paid to him. 

To
avoid any and all doubt, it is hereby explicitly agreed that payment or non- payment of whatever Insurance compensations by the Insurer, shall not relieve the  Other Contractor from his liability imposed
on him under the provisions of the present Contract, or by Law, including—in the event that the
Insurance does not cover the cause of action or in the event that the Insurance compensations are insufficient to cover the injury and/ or damage caused and/ or claimed and/ or ruled by the Court or
any other event. 

	12.
	The costs of stamping this Contract shall apply to the Other Contractor.

	13.
	For the purpose of this Contract, the Parties' addresses shall be as follows: 

	 	Orderer	 	:	 	24, Haparsim Street, Haifa
	

 	

Contractor	
 	

:	
 	

............................................
	

 	

Tenant	
 	

:	
 	

............................................
	

 	

Other contractor	
 	

:	
 	

............................................

IN WITNESS THEREOF, THE PARTIES HAVE SIGNED ON THE ABOVE DATE AND SITE:  

	 	 	 	 	 
	
 Orderer	 	
 Contractor	 	
 Other Contractor
	

 	
 	

 	
 	

 
	
 Tenant	 	 	 	 

6

 
 

ANNEX F    
    
    CONTRACT    
    

        Entered into and signed at: Haifa, on ..........th day of month ...................., year .................... 

Between: 

	MATAM, Haifa Industrial Data Center Ltd.	 	 
	

(hereinafter referred to as: "MATAM")	
 	

 
	 	 	on the one hand
	and:
	...............................................

(hereinafter referred to as: "the Tenants	 	 
	 	 	on the other hand
	 	 	 

	Whereas	 	MATAM is the owner of the rights at the Haifa Industrial Data Center (hereinafter: "the Center");
	

and whereas	
 	
MATAM has built, is building and causing to build and develop at the Center for the Tenants' use
therein;
	

and whereas	
 	
MATAM is the owner of the assets situated at the Center that are used for servicing the various Tenants;
	

and whereas	
 	
MATAM has a special interest to implement and normally provide services to all the Center Tenants;
	

and whereas	
 	

the Parties wish to set up a Service Company that would arrange and offer services at the Center, both to the plants that constitute a Party to this Contract and to the Center future Tenants;

THE PARTIES HAVE THEREFORE STIPULATED AND AGREED AS FOLLOWS:  

	1.
	The
Preamble to this contract constitutes an integral part thereof and shall be considered as included therein.

	2.
	Definitions
in the Contract are as defined hereinafter: 

	 	 	Assets	 	—	 	All the assets assigned to service the Center Tenants, including fences, lighting installations, roads, sidewalks, gardens, irrigation equipment, water mains, sewage mains,
fire extinguishing, cooling towers, machinery room structure, transformation structures and all equipment, machinery and accessories found therein;
	

 	
 	

Equipment	
 	

—	
 	

Part of the assets specified under Annex A and being transferred to ownership of the Service Company;
	

 	
 	

Optional Equipment	
 	

—	
 	

The said part of assets used solely and only by those who receive the optional service (including the machinery room and all the equipment and accessories included therein, the transformation and transformers connected thereto, and all the piping
system connected with rendering the service).

	3.
	The
Parties shall establish a Private Company which target shall be to maintain and operate the assets and render the service to all Center
Tenants, under the terms to be specified hereafter under the provisions of this Contract.

	4.
	The
Parties explicitly agree that the principles concealed in this Contract shall serve as a binding basis to the Memorandum and Statutes of Association of the Service Company to be
soon erected. 

 
	5.
	The
Service Company shall be responsible for providing the Center Tenants with the following services:

	a.
	Supply
of air conditioning, compressed air, heating (hereinafter: "the Optional Service"), for those  Tenants who shall ask to obtain this service.

The
Parties agree that the Service Company shall render the Optional Service to every Tenant who, in the
context of the Agreement he signed with MATAM, has concluded that this service would be rendered to him. 

Also,
the Parties agree that any Tenant who asked to obtain the Optional Service would not be able to
withdraw from receiving the service after he signed the said contract with MATAM, and he shall be obligated to pay the full price for the  Optional Service;

	b.
	General
maintenance of the Center, the buildings serving the Center, the existing
equipment at the Center' roads' sidewalks, gardens, lighting, water mains, sewage mains. Fences as well as security services, cleaning and a clinic at
the Center (hereinafter: "Mandatory Services"). The Service Company can decide what would be the
additional services rendered to the Tenants that would become mandatory. 

The
Service Company Mandatory Services are considered compulsory and shall be given to all the Tenants
within the Center area, with no exception. 

	6.
	The
Service Company is under the absolute obligation to operate in good order the assets and/ or equipment, including the optional equipment, through proper maintenance as required to
ensure this obligation, and also through reconditioning and/ or replacement and/ or completion of the said assets and/ or equipment, thus to ensure their proper operation.

	7.
	The
Service Company shall bear all the expenses and investments required for giving the services and ensuring the Company's adequate operation as mentioned under the provisions of this
Contract, among others and including:

	a.
	The
expenses and departures, direct and indirect, substantially involved in giving the services;

	b.
	The
funds and investments required for protecting the assets, the maintenance and/ or replacement and/ or reconditioning and/ or completion thereof, if need should arise;

	c.
	Investments
in a fund for equipment renewal;

	d.
	Expenses,
departures and payments, which were not mentioned hereinabove and connected with the Service Company operation.

	8.
	Should
it be required to do so, the Service Company shall care, in person and through its own initiative, obtain from the competent authorities all the required licenses, and it shall
bear all the expenses thus incurred.

	9.
	The
Service Company shall employ an employee and/ or employees of its own, to fulfill its functions.

	10.
	The
Parties hereby explicitly agree that the Service Company shall bear all responsibility with regard to any damage that may be caused to its employees, its delegates, and any damage
that may be caused to any Third Party and/ or any other agency and/ or corporation whatsoever and/ or the representatives thereof and/ or employees and/ or delegates relating to all the operations
deriving and/ or involving and/ or connected to the Service Company operations.

	11.
	The
Service company is under the obligation to insure its employees at its own cost, through an Employers' Liability Insurance; also, insure through a Third Party Liability against
any damage that may be caused to any Third Party, including MATAM, its customers and any other individual and/ 

2

 

or
any other agency and/ or corporation, resulting from any negligent operation and/ or failure that may be made under the provisions of this Contract and/ or outside thereof. 

	12.
	The
Service Company, immediately upon its being set up, shall insure the machinery room, building 4 and the transformers booths and/ or any other structure (hereinafter: "the  Structures"), that will be
delivered for the Service Company's use, as well as all the machines, instruments and any other and/ or additional attachment
delivered by MATAM to the possession and use by the Service company. 

The
Service company shall insure at its cost the Structures and equipment against risks of fire, breakage cover that would enable renovation of the
equipment to its former status, earthquakes, floods in regular industrial structures and also against additional special risks deriving from manufacture processes and storage of materials as shall be
performed by the Service company. 

The
Policy amount in establishing value, as will be from time to time, shall be adjusted among the Parties to the present Contract and the Service Company undertakes that the said Policies shall
remain valid throughout the entire Contract period. 

The
Service Company shall pay the insurance premiums on the Insurances mentioned hereinabove and it shall be under the obligation to submit to MATAM,
upon request, the said Insurance Polices and/ or any part thereof, and the receipts to evidence payment on the said insurance premiums. 

Without
prejudice to the generalities mentioned hereinabove and in order to ensure that the statements, the Service Company and MATAM shall be mentioned
as beneficiaries on all the Policies, all the funds to be received shall be consecrated to restoring the Structures and the equipment to their former
state. 

Without
prejudice to the generalities mentioned hereinabove, the Service Company shall undertake that all its employees and/ or those on its behalf in the  Structures area and/ or the Center, shall be under its obligation alone, and  MATAM shall not be in any way whatsoever responsible for them. 

Also,
it is explicitly agreed that any injury that may be caused to any individual whatsoever or to any asset, resulting from a Service Company operation, shall be under the exclusive responsibility
of the Service Company and it shall indemnify and compensate MATAM with no exception for any complaint and any claim that may be filed against  MATAM.

The
Service Company shall be responsible toward MATAM and towards any Third Party for any damage or loss that may be caused to the  Structures and or the other
structures and also/ or to its property for whatever cause whether it is connected, involved or deriving from the Service
Company direct or indirect operations in the Structures and/ or equipment and/ or in the context therein. 

At
any rate, the Service Company is hereby under the obligation towards MATAM and shall indemnify it for any damage or loss and also/ or any claim to
pay indemnification from any individual or agency whatsoever who would obtain a final ruling against MATAM or as a result of a claim that would be filed
against MATAM in the above- mentioned context and would bring about a final ruling against MATAM. 

The
Service Company undertakes, immediately upon its foundation, to purchase Insurance against all the said damages with an Insurance Company, and deliver a copy of the Insurance Policies to  MATAM.

	13.
	Tenants shall bear directly all the obligations imposed on the Service Company under the provisions of this contract, thus until the
final establishment of the Service Company and until the Service Company has adopted the provisions under the present Contract. 

3

 
	14.
	It
is unequivocally declared that the Service Company is responsible towards the Tenants and towards  MATAM for rendering services and overall maintenance to
the Center including everything therein, and
that MATAM is not responsible and/ or not under the obligation to provide any service and/ or maintenance whatsoever in the event that none of the
contracts include an obligation on MATAM part to provide either service and/ or maintenance. Signature on a contract voids the provisions under a
previous contract and unconditionally releases MATAM from the said obligation. The Service Company shall indemnify  MATAM for any damage and/ or claim filed
in connection with rendering and/ or not rendering services at the  Center.

	15.
	Without
prejudice to the generalities stated under the previous Clauses, the Service Company shall indemnify MATAM for all the expenses
it incurs on account of the amounts it would be obligated by the Courts to pay in conjunction with operations and/ or failures performed by the Service Company and/ or its employees, users, agents,
representatives and/ or any other individual outside this Contract.

	16.
	Tenants shall pay to the Service company services fees that shall be defined every year by the Service Company and at the dates to be
fixed, according to the following key:

	a.
	For Optional Services :

According
to the ratio between the plant area and the area of all the plants together that are using the Optional Services.

Any
plant that does use the Optional Services shall be exempt from pay the said part of service fees that apply to the Optional
Services; 

	b.
	For Mandatory Services :

According
to the ratio between the plant area and the total Premises area at the Center; 

	c.
	For Special and Specific Services :

According
to the pricelist to be defined for the service by the Service Company. 

	17.
	It
is explicitly hereby agreed that when calculating the service fees for each of the above- mentioned services, all the expenses, direct or indirect, involved in the rendering of
said services shall be taken into consideration.

	18.
	The  Optional Services users are under the obligation to allocate payments for the Equipment Renewal Fund at rates that shall be based
on equipment decrease within 7 years, thus in addition to the above- mentioned service fees, for every and each month. 

In
the event that funds that the Service Company has set aside in this matter, are in due course insufficient to renew the equipment and/ or part thereof, the Optional
Services users shall be under the obligation to immediately complete any amount required for renewing the said equipment. The
allocations and completions hereinabove shall be performed by every Tenant, in conformance with the key specified under Clause 16(a) above. 

	19.
	MATAM shall transfer to the Service Company ownership equipment at the price that was estimated at IL. 9,500,000 by the Assessor,
Dr. Smeltz.

	20.
	MATAM shall give the Service company an owners' loan of IL. 9,450,000, under the following terms:

	a.
	The
loan shall be not repaid to MATAM, only except upon the Company's liquidation;

	b.
	The
loan shall bear a yearly interest of 1% rate, one half of which shall be linked to the Customer Price Index, whereas the basic Index is that of June 1976; 

4

 

	c.
	The
Service Company shall pay to MATAM the interest and linkage thereof in monthly and consecutive payments at the beginning of every
month.

	21.
	It
is explicitly agreed that MATAM shall be entitled to enjoy the services offered by the Service Company and shall be exempt of any
payment to the Service Company whatsoever on account thereof, both for the Optional Service and the Mandatory
Services.

	22.
	The
Service Company capital stock shall be of IL. 50,000 (fifty thousand Israeli Lira), divided into:

	a.
	100
management shares, each of IL 1.— The management shares rights shall be as follows:

	(1)
	Voting
rights at the General Assemblies and Board of Directors Assemblies;

	(2)
	Right
to convene and hold any Board of Directors Meeting of the Service Company;

	(3)
	Right
to convene and hold any General Assemblies of the Service Company.

	b.
	For
the sake of holding a quorum at the Company Board of Directors Meetings and General Assemblies, at least 60% management shareholders must be present;

	c.
	MATAM shall be allotted 50 management shares;

	d.
	The
remaining 50% management shares shall be allotted among all the Tenants according to the ratio between the area held by every  Tenant and the overall
Center Premises for Hire, as it appears from time to time (hereinafter: "the  Tenants' Shares");

	e.
	The  Tenants' Shares shall be consigned with a trustee agreed upon (hereinafter: "the  Trustee"). Every year and/ or after the admission and/ or the departure of a Tenant from the  Center, the Trustee shall decide the voting rights for every  Tenant at the Center;

	f.
	49,900
regular shares, each of one Lira, bestowing to the shareholders the right to the Company's profits and division of the Company's excess in case of liquidation; these shares
shall be allotted as follows: 

	(1) MATAM	 	49,899 shares
	(2) The Economic Co.	 	1 share

	23.
	In
the event that addition and expansion beyond and over the plants and the structures that existed at the Center as at 1.8.1976, and
should MATAM decide to add any equipment, the said equipment should be delivered by MATAM to the Service
Company on exactly the same terms and conditions according to which the equipment subject-matter to this Contract was delivered, provided that MATAM be
given the right to collect monies from a newly admitted Tenant and/ or an existing Tenant who would rent
additional areas in the Center, thus in consideration for his right to enjoy the Service company Optional
Services.

	24.
	It
is explicitly agreed that the Service Company shall be under the obligation to affiliate any plant and/ or Tenant who would sign a  Tenancy Agreement with
MATAM, thus in conformance with the existing standards and principles that are
customary at the Service company at the said time period.

	25.
	It
is explicitly agreed that the final settling of accounts with a departing Tenant who used the Optional
Services at the Center shall be performed on the basis of the following formula: 

	(Area of the Departing Plant
 Area of the Optional Sce Participants	 	×	 	Equipment at foundation value - (Equip. value + Value of Principal

If
the amount resulting from the said formula when calculating from right to left is positive, the said amount should be credited to the departing plant, and if negative, it should be debited to the 

5

 

departing
plant, which would have to pay the said entire amount to the Service Company upon leaving the Center. 

	26.
	It
is explicitly agreed that when a newly admitted Tenant at the Center or a  Tenant who is renting new areas
and wishes to use the Optional Service, he would pay the Service company
according to the same principles according to which the existing plants are paying. However, in the event of a need to complement monies as stated under Clause 18 hereinabove, the new  Tenant shall
pay a smaller amount in relation with the difference in foundation values from the date of his admission to the event date and the
foundation value on the event date.

	27.
	It
is explicitly agreed that all the generalities and payments including the generalities and payments concerning the Service Company equipment replacement and/ or the debit and/ or
credit of the departing Tenants from the Center and/ or being admitted to the  Center, shall apply on all the
Tenants present at the time of signature of this Contract and all the
potential future tenants.

	28.
	Tenants are under the obligation to implement in full all the Service Company decisions in their entity, and explicitly declare that
they know that the Service Company has the authority to cease rendering the service to the Tenant who does not implement the Service Company decisions,
thus without prejudicing any one of the rights of the Service Company and/ or MATAM and/ or the other firms that are fulfilling their duties under the
provisions of the present Contract.

	29.
	To
ensure the Tenants' obligations as stated under the provisions of this Contract, and especially to ensure performance of the
payments and debits charged to the Tenants upon the equipment replacement and/ or renewal and/ or at the time of departure, the  Tenants shall consign with
MATAM two (2) promissory notes, as follows:

	a.
	One
promissory note for the purpose of performing ongoing payments;

	b.
	The
second promissory note to cover the imparity at the departure time from the Center;

	c.
	Power
of Attorney in favor of MATAM, to fill the above- mentioned promissory notes with the amounts and maturity dates, and collect the
said debt in favor of the Service Company. 

It
is explicitly agreed that only in the event that a Tenant does not fulfill his obligations under the provisions of this Contract,  MATAM shall be entitled
to hand over the promissory notes to the Service Company, so that it is in a position to materialize the
Tenants' debts, thus without any prejudice to any right from the rights of the Service Company and/ or  MATAM. 

	30.
	To
avoid any doubt, the Tenants are hereby under the obligation towards MATAM to bear
all the expenses and motions of any kind and type whatsoever that are required and involved in the Service Company proper operation.

	31.
	Disputes
with the Service Company, which are not resolved shall be brought to the ruling of a single Arbitrator to be appointed by the Parties, and if still unresolved, to the
decision of an Arbitrator to be appointed by the Mayor of the City of Haifa.

	32.
	The
Parties declare that upon signing the present Contract, all previous arrangements and/ or agreements shall be automatically cancelled, in connection with the Service Company, and
that this Contract is unique and binding the signatories concerning the Service Company, and it shall become valid as of 7th June 1976.

	33.
	Any
notification from any of the Parties to any other under the provisions of this Contract shall be dispatched by registered mail to the addressee, according to his address as
mentioned in this Contract, and it will be considered as having been duly received 48 hours following dispatch. 

6

 

The
Parties' addresses for the purpose of this Contract: 

Haifa
Industrial Data Center Ltd., MATAM, Haifa

............................................, MATAM Haifa. 

	34.
	Cost
o stamping the Contract shall be proportionally divided among all the Center Tenants and shall be paid by them. 

IN WITNESS THEREOF, THE PARTIES HAVE SIGNED AS FOLLOWS:  

 At Haifa, on this....th day, of month....................., Year..........  

	 	 	 
	
	 	

	Haifa Industrial Data Center Ltd.	 	 

7

 
 

ANNEX H    
    

Date:................................ 

Messrs.

MATAM, Haifa Industrial Data Center Ltd.

MATAM Postal Agency 31905

Haifa 

Re:
BANK GUARANTEE

As
requested by: ........................ (hereinafter referred to as: "the Applicants"), we are under the obligation to pay you any amount up to the
sum of NIS. ...................... (...................... New Shekels) only (hereinafter referred to as: "the Amount Pledged") that you will request in
relation with the Contract dated ......................., thus within 5 (five) days from the date of your first demand in writing directed to us without imposing on you any obligation to establish or
evidence any justification for this, your request. 

The
Amount Pledged, and any unpaid amount thereof, shall be linked to the Israeli Consumer Price Index as follows: 

	(1)
	If
it should appear that on the mature date of actual payment, as per this Letter of Guarantee, that the Israeli Consumer Price Index on the date the payment was actually performed
(hereinafter: "the New Index") has increased over ................ points (hereinafter: "the Basic
Index"), we shall pay you the Pledged Amount, or any part thereof, as increased by the maximum rate of the increased  New Index
versus the Basic Index, all as per the highest rate.

	(2)
	For
the purpose of this, our guarantee—the New Index—the Israeli Consumer Price Index known on the date payment
is actually performed, as published by the Central Bureau of Statistics and/ or any competent agency that should replace it prior to the date that payment is actually performed. 

Any
amount requested shall be paid to you without having to impose on you the necessity to first justify your request, and without the obligation for you to demand payment from the  Applicants, first,
subject to the entire amount that we should have to pay under this, our guarantee, does not exceed the Amount
Pledged linked as state hereinabove. 

This,
our guarantee shall stand for the period up to ........................ (date) inclusively, and any demand behalf thereof that is received after this date shall not be consented to. 

This
guarantee is Irrevocable and without any condition. 

This
guarantee cannot be endorsed and/ or transferred. 

Yours
Faithfully, 

	
 Bank	 	 

 
 

ANNEX H-1    
    

Date:................................ 

Messrs.

MATAM, Haifa Industrial Data Center Ltd.

MATAM Postal Agency 31905

Haifa 

Re:
BANK GUARANTEE

As
requested by: ........................ (hereinafter referred to as: "the Applicants"), we are under the obligation to pay you any amount up to the
sum of NIS. ...................... (...................... New Shekels) only (hereinafter referred to as: "the Amount Pledged") that you will demand
concerning payment for a request for changes and additions to the Contract dated ......................., thus within 5 (five) days from the date of your first demand in writing directed to us without
imposing on you any obligation to establish or evidence any justification for this, your request. 

The
Amount Pledged, and any unpaid amount thereof, shall be linked to the Israeli Consumer Price Index as follows: 

	(1)
	If
it should appear that on the mature date of actual payment, as per this Letter of Guarantee, that the Israeli Consumer Price Index on the date the payment was actually performed
(hereinafter: "the New Index") has increased over ................ points (hereinafter: "the Basic
Index"), we shall pay you the Pledged Amount, or any part thereof, as increased by the maximum rate of the increased  New Index
versus the Basic Index, all as per the highest rate.

	(2)
	For
the purpose of this, our guarantee—the New Index—the Israeli Consumer Price Index known on the date payment
is actually performed, as published by the Central Bureau of Statistics and/ or any competent agency that should replace it prior to the date that payment is actually performed. 

Any
amount requested shall be paid to you without having to impose on you the necessity to first justify your request, and without the obligation for you to demand payment from the  Applicants, first,
subject to the entire amount that we should have to pay under this, our guarantee, does not exceed the Amount
Pledged linked as state hereinabove. 

This,
our guarantee shall stand for the period up to ........................ (date) inclusively, and any demand behalf thereof that is received after this date shall not be consented to. 

This
guarantee is Irrevocable and without any condition. 

This
guarantee cannot be endorsed and/ or transferred. 

Yours
Faithfully, 

	
 Bank	 	 

 
 

ANNEX J    
    
    ANNEX MATAM INSURANCE    
    

	A.
	Without derogating from the Tenant's obligations under the present Contract and according to the Law, prior to commencing the
performance of any works whatsoever in the premises for hire that are not parallelly included in the works framework, whether they are performed by the Tenant, and also / or on his / her behalf and
also / or on his / her account (except for the works performed by MATAM), the Tenant is under the obligation to prepare at his / her expense and under his / her responsibility, an "Insurance for Works
under Erection" (as specified hereinafter, after this Section), in relation to all works performed in the premises for hire by him / her, and also / or on his / her behalf and also / or on his / her
account (except for the works performed by MATAM). The Insurance for Works under Erection shall be made out to the name of Tenant, Contract ors and subcontractors and MATAM, for the period throughout
the works performance, and in addition thereto throughout the inspection period that shall not be less than 12 months from the said works termination date and shall include the following
Insurance Sections:

	(1)
	Chapter 1—

All
Risks Insurance covering full value of the entire Tenant's works being performed in the premises for hire. This Chapter shall include a clause relating to waiving substitution towards the
remaining edifice tenants and occupants (whose property Insurance also include a parallel waiver towards the Tenant), on account of any damage they may cause, except for damage caused through
malicious intent. The Chapter shall include an explicit extension concerning the property where work is being performed and also / or the adjoining property, with limited liability of no less than US$
100,000 (one hundred thousand US dollars) on first damage basis; 

	(2)
	Chapter 2—

Insurance
to cover Third Party Liability, liability of no less than US$ 1 mio. (one million US dollars). This Section shall include a cross liability clause, according to which the Insurance shall be
considered as having been made separately for each of the insured's individuals. Also, and in order to avoid any and all doubts, it shall be mentioned that MATAM's property that is not under the
Tenant's control and/ or holding shall be considered as Third Party's property in the matter of this Chapter; 

	(3)
	Insurance
coverage for Employers' Liability on account of liability towards all those employed in performing the works, with limited liability of no less than US$ 5 million
(five million US dollars) per case and per period. 

This
Insurance shall not include and limitation concerning Contract s, subcontractors and their workers, as well as youth employment. 

The
Insurance covering Works under Erection shall include an explicit condition according to which it precedes any Insurance made by MATAM. 

	B.
	The Tenant is under obligation is issue to the Company—without any need for request or demand on the Company's part, and no
later than on the tenancy commencing date or on the date any works whatsoever are commencing at the premises for hire (the sooner date)—a confirmation concerning the Erection Insurance
purchase, according to the formulation "Erection Insurance Confirmation", as signed by the Insurer, according to the Law. 

The
Tenant declares that he / she is aware of the fact that issuance of the said "Erection Insurance Confirmation" is a suspending and prerequisite condition for his / her performance of works in the
premises for hire and also / or for giving a borrowing period, and in the event that the said confirmation was not issued prior to the said date, the Company shall be entitled to prevent the Tenant
from performing the works at the premises for hire. 

 
	C.
	Without derogation from the Tenant's undertakings under the provision of the present Contract and under the Law, prior to the Tenant's
business date at the premises for hire or prior to the date of bringing in whatever assets into the premises for hire—the sooner among both dates—the Tenant undertakes to
purchase and implement—at his / her own cost and under his / her responsibility throughout this Contract duration—the Insurance s specified hereinafter following this Section
(hereinafter referred to as: "Insurance of the Premises for Hire"), with a competent and reputed Insurance Company:

	(1)
	Insurance
to cover the premises' contents, equipment serving the premises for hire owned by the Tenant and also / or under his / her responsibility, and is located outside the
premises within the area range, as well as any repair, change, improvement, renovation and addition to the premises, that were performed and/ or shall be performed by the Tenant and/ or on his / her
behalf, and also furniture, equipment, installations and inventories of any type and kind whatsoever, against loss or damage due to fire, smoke, lightening, explosion, earthquake, riots, strike,
willful damage, flood, storm and tempest, impact by vehicle, impact by airplane, water damages, power damages, broken glass and burglary;

	(2)
	Insurance
covering Consequential Loss caused to the Tenant following loss or damage pursuant to the risks specified under sub- Section C(1) above, that may be
caused to property as specified under sub- Section C(1) above and/ or to the building structure, and thus in the appropriate amounts of Insurance and for suitable periods of
indemnification. 

The
Tenant is entitled not to purchase this Insurance ; however, in such an instance, the provisions under Section E hereinafter shall apply, as if the said Insurance for Consequential Loss had
been purchased by the Tenant; 

	(3)
	Insurance
for Third Party Liability, with limited liability of no less than an amount equal in NIS (New Israeli Shekel) to US$ 1 million (one million US dollars) per event;
this Insurance is not subject to any limitation concerning liability due to five, explosion, fright, hoisting, loading and unloading instruments, defective sanitary installations, poisoning, any food
or drink hazard, as well as claims made by the National Security Fund. The Insurance shall be extended to indemnify MATAM and also / or the Management Company for their liability as the premises'
owners and also / or as owners of other rights in the premises and also / or as the premises' management and also / or as providers of services in the premises—thus subject to the Clause
according to which the Insurance shall be considered as having been separately purchased for each of the Insured's individuals;

	(4)
	Insurance
for Employers' Liability on account of the Tenant's liability towards all those he / she employs or on his / her behalf, within the liability limitations generally
acceptable on the Israeli Insurance market at the time of the Insurance purchase and / or renewal. The said Insurance shall not include any limitation with regard to Contract ors, subcontractors and
their workers, decoys, poisons and employment of youth. 

The
Insurance s for the premises shall include an express condition according to which they precede any other Insurance purchased by MATAM and also / or the Management Company. Also, the Insurer
undertakes that the policies shall not be diminished, not cancelled and not expired unless the Tenant has received the Company's approval, in writing and in advance, to reduce or cancel the said
policies. 

	D.
	The Tenant is under the obligation to update the Insurance amount on account of the Insurance that was purchased under the provisions of
Clause C(1) hereinabove, from time to time, so that the said amounts reflect at all times the insured property's full value. 

2

 

The
Tenant is under the obligation to use the funds received from the Insurance Company on account of the Insurance stated under Clause C(1) hereinabove, only for the purpose to immediately
restore the damages covered by the said Insurance. 

	E.
	The Tenant declares that he / she will have no claim and/ or demand and/ or complaint versus MATAM and/ or the Management Company, on
account of damages for which he / she is entitled to indemnification, as per the Insurance purchase in conformance with Clauses C(1) and C(2) hereinabove (or that he / she would have been entitled
thereto if it were not for his / her self participation for excess Insurance), and he / she hereby releases MATAM and/ or the Management Company of any liability to the said damage. The provisions
under this Clause shall supplement (rather than prejudice) any other provision under the present Contract, with regard to liability discharge towards MATAM and/ or the Management Company;

	F.
	Without the need for any request on the Company's part, the Tenant is under the obligation to hand over to the Company—not
later than the Tenant's business opening date at the premises for hire or prior to the date of bringing in whatever assets into the premises for hire (the sooner date) a purchase confirmation
concerning the "Premises for Hire Insurance Confirmation", as signed by the Insurer according to the Law. 

The
Tenant declares that he / she is aware of the fact that issuance of the said "Premises for Hire Insurance Confirmation", is a suspending and prerequisite condition for handing over holding of the
premises for hire and also / or bringing in whatever assets into the premises for hire, and the Company shall be entitled to prevent the Tenant from opening his / her business at the premises for hire
and also / or and also / or bringing in whatever assets as stated, in the event that the said confirmation was not issued before and on the date mentioned hereinabove; also, the Tenant is under the
obligation to hand over to the Company original copies of the premises Insurance s within 30 (thirty) days prior to the Insurance period commencing date, as stated therein; 

	G.
	For avoidance of any and all doubts, it is clarified that non-issuance of the Insurance confirmations and Insurance Policies
on the date stated under the provisions of Clause F hereinabove, shall not liberate the Tenant from any of his / her obligations under the provisions of the present Contract,
including—and without derogating from the generalities hereinabove—any payment obligation applicable to the Tenant, and the Tenant undertakes to implement all his / her
obligations under the provisions of the present Contract, even though he / she is prevented—because of non-issuance of the confirmations on due date—from performing
any work and also / or receiving the holdings of the premises for hire and also / or bringing in assets to the premises and also / or opening his / her business in the premises;

	H.
	The Tenant is under the obligation to fulfill the Insurance Policies terms and conditions, to pay the Insurance premiums in full and on
due dates and to care and ensure that the premises Insurance Policies shall be renewed from time to time as required, and remain valid throughout the entire tenancy;

	I.
	No later than 14 (fourteen) days following termination of the premises Insurances period, the Tenant shall be under the obligation to
entrust the Company with the confirmation of Insurance purchase as stated under the provisions of Clause F hereinabove, to certify the validity thereof for an additional one (1) year;
and the Tenant shall also entrust the Company with original copies of the premises Insurance, thus within 30 (thirty) days from the said Insurance renewal date. The Tenant shall be under the
obligation to again entrust the Company with the Insurance purchase certificate and original copies of the premises Insurance Policies, on the nominal dates for each Insurance year and throughout this
Contract validity period; 

3

 
	J.
	The Company is entitled to review the Insurance Certificates and also / or Insurance Policies handed over by the Tenant, as stated
above, and the Tenant is under the obligation to perform any change or alteration required in order to conform them with the Tenant's obligations. 

The
Tenant is under the obligation and declares that the Company's revisal entitlement concerning the Insurance Certificates and Policies and the right to check the Policies and order the above
specified corrections do not impose any obligation nor responsibility on the Company and/ or whomever on its behalf, with regard to the said Insurance Certificates and Policies, the nature, scope or
the lack thereof, and do not intend to lessen any obligation whatsoever as imposed on the Tenant under the provisions of the present Contract; 

	K.
	The Tenant undertakes not to make and / or allow others to make any deed or failure in the premises and/ or the building, which might
cause explosion and/ or conflagration and/ or anything that might bring about the increased insurance expenses applying to MATAM and/ or the Management Company and also / or the other tenants, on
account of the building and the premises on hire thereof;

	L.
	Cancelled;

	M.
	Without derogating from the Tenant's obligations under the provisions of the present Contract and according to the Law, MATAM and/ or
the Management Company shall purchase Insurance Policies as specified hereinafter, keeping them valid throughout the tenancy:

	(1)
	Insurance
to cover Employers' Liability—to insure the obligations of MATAM and/ or the Management Company towards their workers, in conformance with the Civil Wrongs
Ordinance (New Formulation), on account of any body injury to the employee while and pursuant to his work in the building and/ or the surrounding area thereof. 

The
Policy shall include a Clause for "Cross Liability". 

In
avoidance of any and all doubt, the Policy shall not insure the Tenant's liability for bodily injury and/ or property inside the premises and/ or in the rented area and/ or designated for hire in
the building; also, it shall not insure liability for bodily injury and/ or property that were caused within the shared areas that were caused within the premises.; 

	(2)
	Insurance
to cover Third Party Liability—to insure the obligations of MATAM, the Management Company and the Tenant towards any Third Party whatsoever within the shared
areas, for an amount to be established from time to time by MATAM or the Management Company, under their sole consideration. 

The
Policy shall include a Clause for "Cross Liability". 

In
avoidance of any and all doubt, the Policy shall not insure the Tenant's liability for bodily injury and/ or property inside the premises and/ or in the rented area and/ or designated for hire in
the building; also, it shall not insure liability for bodily injury and/ or property that were caused within the shared areas that were caused within the premises. 

The
Policy shall be extended to cover MATAM's obligations relating to anything connected with its being the building owner; 

	(3)
	Property
Insurance—to cover the building structure and any other asset belonging to MATAM and/ or the Management Company within the building area and the surroundings
thereof, for any loss or damage due to risks of: fire, explosion, earthquake, storm and tempest, flood, water damages, impact by airplane, collision, strikes, riots, willful damage, burglary, broken
glass, as well as any additional risk that the Company and/ or the Management consider necessary. 

4

 

The
said Insurance shall include a Clause concerning cession of right to waiving substitution towards the Center tenants due to damage they inadvertently caused themselves to the building structure. 

For
the purpose of this Clause, the term "structure" shall include all the systems that constitute an integral part of the building, and explicitly it shall not include the premises contents and any
extension, improvement or expansion that were performed in the rented premises by the tenants or on their behalf. Tenants undertake that there is nor shall there be any mortgage or seizure on the
building subject- matter of the present Contract throughout the tenancy, and in the event of loss or damage, the insurance compensation to be paid by the Tenant's Insurance Company shall be designated
and shall solely be used for renovating and/ or repairing the damages to the structure; 

	(4)
	Insurance
to cover loss of rent and management expenses that shall be caused to MATAM and/ or the Management Company, due to damage caused to the building hired or due to the rented
building demolition on account of the risks specified under the provisions of Clause C(3) hereinabove for an indemnification period of 12 (twelve) months. 

In
the instance of Insurance purchase as stated under the provisions of Clause C(4) hereinabove, and inasmuch as the Tenant persists to pay the management fees, the Tenant shall be exempt from
paying the rent and management expenses in the said instances and throughout the period that the Insurance Company shall pay the rent and management expenses to MATAM. 

MATAM
declares that it shall have no claim and/ or demand and/ or complaint versus the Tenant on account of the damage for which it is entitled to compensation according to the Insurances that were
purchased under the provisions of Clauses M(3) and M(4) hereinabove, or would have been entitled to compensation in conformance thereto if it were not for the self- participation for
excess Insurance, and MATAM hereby releases Tenant of any liability to the said damage; 

	N.
	The following provisions shall be applicable to the Policies stated under Clause M above:

	(1)
	MATAM
and/ or the Management Company shall be entitled from time to time to perform additional Insurances, all at their own sole discretion and under the condition that all through
rental the Policies have remained in full validity;

	(2)
	The
Policies shall be available to the Tenant's review at the Company's offices, upon early coordination. Tenant shall be entitled to purchase under his / her consideration and at his
/ her cost any other Insurance, whether complementary or supplementary to the said Policies—thus in the event that Tenant is not fully satisfied with the said Policies or he / she
considers that they do not correspond to the building and/ or premises needs;

	(3)
	Tenant
is under the obligation to strictly and fully implement all the Policies provisions, in order to preserve the rights of MATAM, the Management Company and all the other
premises' tenants in the context of the Policy;

	(4)
	Tenant
shall cooperate with MATAM and the Management Company in case of litigation with the Insurance Company, and he / she shall immediately provide any document, evidence, and such
as may be required for filing a suit;

 

	O.
	Cancelled;

	P.
	In this Annex, the terms below shall have the following meanings:

	(1)
	Damage—its significance under the Civil Wrongs Ordinance, including indirect damage, involved damage, resultant damage,
loss of income and damage to reputation;

	(2)
	MATAM—the Company, the Gav Yam Holdings Co. Ltd., the Haifa Economic Co. Ltd. And Shatam Haifa Ltd.
The Company shall be the delegate of all the said factors under the present sub- Clause, in everything connected thereto, in this Annex. 

5

QuickLinks

Exhibit 10.11

ANNEX A TECHNICAL SPECIFICATIONS—ZORAN—WRAPAROUND WORKS

ANNEX D QUADRILATERAL CONTRACT

ANNEX F CONTRACT

ANNEX H

ANNEX H-1

ANNEX J ANNEX MATAM INSURANCEQuickLinks
 -- Click here to rapidly navigate through this document
  

 
 

Exhibit 10.36    
    

Ref. GLUSMAN/MATAM/SM/07/03/98

[TRANSLATED FROM THE HEBREW] 

 
 

AGREEMENT    
    

Made
and signed in Haifa this                             day
of                                         
                 1997
 

	

Between:	
 	
Matam—Science Industries Centre Haifa Ltd

Pc 51-068740-3

(hereinafter referred to as "the Company")
	

 	
 	
of the one part
	

And:	
 	
Zoran Micro-Electronics Ltd

PC 51-094944-9

(hereinafter referred to as "the Tenant")
	

 	
 	
of the other part
	

Whereas	
 	

the Company is the exclusive possessor of and owner of the rights in land situated in the Haifa Science Industries Centre (hereinafter referred to as "the Centre") which constitutes part of parcels 7 and 8 in block 10730 (hereinafter referred to as
"the plot");
	

And Whereas	
 	

the Company has erected a building on the plot which is known as building 30 (hereinafter referred to as "the building");
	

And Whereas	
 	

the building's construction was completed after 20th August 1968 and the tenants' protection laws, including the Tenant's Protection Law (Consolidated Version), 1932-1972 does not apply to the premises;
	

And Whereas	
 	

the Tenant warrants that it is an "approved enterprise" within the meaning thereof in the law and that it wishes to rent the premises as defined below in order to establish its plant as defined below;
	

And Whereas	
 	

the Company wishes to let to the Tenant and the Tenant wishes to rent from the Company on an unprotected tenancy an area in the building as specified in the technical specification and plans annexed hereto as appendices "A" and "B" respectively and
constituting an integral part hereof;

Accordingly, it is warranted and agreed between the parties as follows:

	1.
	Recitals and Appendices

	(a)
	The
recitals and appendices hereto constitute an integral part hereof.

	(b)
	The
clause headings have been introduced for reading convenience only, they do not constitute a part of this agreement and should not be used for the purposes of interpretation.

 

	2.
	Interpretation

	

	Without
derogating from the other definitions appearing herein, the following expressions shall be interpreted as follows:

	

	"The building"—the building known as building 30 in which the premises are situated; 

1

 
	

	"The premises"—an area of approx. 1,646 square metres comprising an area of approx. 1,342 square
metres on the fifth floor of the building and an area of approx. 304 square metres on the ground floor of the building, all as marked in the colour red on the drawing annexed hereto as appendix "B/1"
and constituting an integral part hereof.

	

	It
is hereby expressed that the aforementioned area includes the Tenant's proportional part of the building's common area as marked with diagonal lines in
the colour blue on the drawing appendix "B/1", and that this area is not included in the area in which the Tenant is being granted, during the tenancy term as defined below, a right of possession, but
only a use right [sic];

	

	"The tenancy term"—the terms defined in clause 5 below, including a tenancy term that has been
curtailed (if curtailed) as a result of any provision hereof and/or as a result of the provision of any law, and any additional tenancy term (if the tenancy term is extended);

	

	"The plant"—the Tenant's business, which is the planning, development and manufacture of
electronic components and products;

	

	"Delivery"—placing the premises at the Tenant's disposal for the purpose of commencing the
tenancy term;

	

	"Common area" means as defined in the Land Law, 5729-1969, including the roof, the entrance area and its
surroundings, the staircases and lobby elevators, the corridors, piping shafts, machine rooms and various conveniences, as marked in the colour blue on the drawing annexed hereto as appendix "B/2".

	3.
	The Nature of The Transaction

	

	The
Company is hereby letting the premises to the Tenant and the Tenant is hereby renting the premises from the Company, for the consideration and on the
terms and conditions specified hereinbelow.

	4.
	The Construction and Acceptance of The Premises

	(a)
	The
premises are being constructed in a size and form pursuant to the annexed technical specification and plans and the finish plan which shall be annexed hereto (appendices "A", "B",
"C" and "C/1" hereto), and all on the terms and conditions and in the manner described herein.

	(b)
	The
Tenant hereby confirms that the technical specification and plans of building no. 30 have been furnished to it and that they are suitable and appropriate for its needs and the
object of the tenancy pursuant hereto.

	(c)
	Without
prejudice to the provisions of sub-clauses (a) and (b) above, it is agreed and warranted between the parties that the interior finish works on the area of the premises
situated on the fifth floor of the building were planned and executed by the Company in accordance with a principal plan which was submitted to the Company by Powerspectrum Technology Ltd and IBM
Israel Science & Technology Ltd. The interior finish plan relating to the area of the premises situated on the fifth floor of the building is annexed hereto as appendix "C".

	

	It
is hereby agreed that the Tenant may, from 15th May 1996 and thenceforth, execute at its expense alterations and/or additions in the area of the
premises situated on the fifth floor of the building, provided that it has received the Company's prior written approval for any addition and/or alteration as aforesaid.

	

	It
is further agreed and warranted by the parties that the interior finish works on the area of the premises situated on the ground floor of the building
shall be planned and executed by 

2

 

the
Company in accordance with an interior finish plan that shall be submitted by the Tenant and approved by Powerspectrum Technology Ltd (hereinafter referred to as "PST"). 

	

	It
is hereby expressed that PST's approval of the aforementioned interior finish plan is one of the terms and conditions for obtaining the Company's
approval of the interior finish plan. The interior finish plan approved by PST shall be submitted by the Tenant for the Company's approval within ten days of the execution hereof.

	

	The
Company warrants that pursuant to an agreement executed between it and PST, it has been agreed that in the absence of a written response to the interior
finish plan from PST within 14 days of the date on which it is conveyed to it, the plan shall be deemed to have been approved by PST.

	

	After
its approval by the Company, the finish plan in respect of the area of the premises situated on the ground floor of the building shall be annexed
hereto as appendix "C/1" and shall constitute an integral part hereof. The Company shall convey the approved finish plan to the Tenant together with an engineering appraisal of the cost of executing
the final works pursuant to the finish plan, which shall be annexed hereto as appendix "C/2". If after the execution of the final works it emerges that there was a quantitative or qualitative
deviation in comparison with the technical specification (appendix "A"), the Tenant shall pay the Company the actual cost of the deviation as provided in clause 7(e) below, provided that in the
event of a deviation from the engineering appraisal of more than 5%, the Tenant's prior written approval of such deviation is obtained (in respect of the part exceeding a 5% deviation). For the
avoidance of doubt, the Tenant's prior consent is not required for a deviation of up to 5% inclusive, and such shall be paid by the Tenant at the Company's request.

	(d)
	

	(1)
	Prior
to the delivery date, as defined in clause 5(a) below, of the area of the premises situated on the fifth floor of the building and the area of the premises situated on
the ground floor of the building, as the case may be, an inspection of the premises shall be carried out by representatives of the Company and the Tenant who shall inspect the premises and confirm to
the parties that they are ready for delivery in accordance with appendices "A", "B", "C" and "C/1".

	

	If
repairs are necessary in order to adapt the premises to the aforegoing, and such repairs are not such as to prevent the Tenant from making reasonable use
of the premises, the Company shall execute them within 60 days, without such derogating from any liability of the Tenant pursuant hereto. In the event that the aforementioned repairs prevent the
possibility of reasonable use of the premises, the delivery date shall be postponed until execution of the repairs preventing reasonable use as aforesaid has been completed.

	(2)
	On
the delivery date of the area of the premises situated on the fifth floor of the building and on the delivery date of the area of the premises situated on the ground floor of the
building, as the case may be, representatives of the Company and the Tenant shall draw up delivery minutes which shall be annexed hereto as appendices "D/1" and "D/2" and constitute an integral part
hereof. Signature of the minutes shall constitute the Tenant's confirmation that the Company has completed all its obligations in respect of the premises pursuant to appendices "A", "B", "C" and
"C/1", and that it does not and shall not have any complaints in respect of the premises, save for complaints specified by the Tenant in the body of the minutes (hereinafter referred to as "the
delivery minutes"). The abstention of either of the parties from participating in the drawing up of the minutes shall not constitute a cause for non-acceptance of the premises and/or any part thereof
and/or for non-performance of the obligations of either of the parties pursuant hereto. 

3

 

	(e)
	It
is agreed and warranted that all the above provisions of this clause regarding delivery dates shall not apply in the case of force majeure, such as war, calamity, general strikes
and lock-outs in Israel in the building industry, a closure of the territories—if and for so long as such a closure is recognised by the Government of Israel in its contracts with the
Israeli Association of Contractors and Builders as force majeure, a natural disaster which cannot be anticipated, acts and/or instructions and/or orders and/or a postponement in respect of omissions
on the part of competent authorities and the like. It is hereby expressed that the duration of the postponement of the delivery date as a result of an incident of force majeure shall be equal to the
period of time during which such incident actually prevents the Company from performing its obligations pursuant hereto.

	5.
	Delivery of Possession of the Premises and the Tenancy Term

	(a)
	The
planned delivery date of the area of the premises situated on the fifth floor of the building is 31st May 1996; however, it is hereby expressed and the parties agree that
the tenancy term for the area of the premises situated on the fifth floor of the building shall commence on the actual delivery date of the area, written notice whereof shall be sent to the Tenant
seven days in advance (hereinafter referred to as "the delivery date of the area of the premises situated on the fifth floor") and shall end on 15th May 1999 or on the date of delivering
alternative premises in a new building that shall be constructed in Matam, whichever is the later, but in any event no later than 15th May 2003 (hereinafter referred to as "the tenancy term for
the area of the premises situated on the fifth floor").

	

	The
tenancy term for the area of the premises situated on the ground floor of the building shall commence within three months of receipt of the interior
finish plans approved by the Company (as provided in clause 4(c) above) and shall terminate at the end of the tenancy term for the area of the premises situated on the fifth floor of the
building.

	

	Written
notice of the actual delivery date of the area of the premises situated on the ground floor of the building shall be sent to the Tenant seven days
in advance (hereinafter referred to as "the delivery date of the area of the premises situated on the ground floor").

	(b)
	Notwithstanding
the provisions of sub-clause (a) above, it is hereby agreed between the parties that the Company may postpone the delivery date of the area of the premises
situated on the fifth floor and/or the ground floor for a further 30 days, and such being on 30 days' prior notice to the Tenant.

	(c)
	Commencing
from the delivery date of the area of the premises situated on the fifth floor of the building or the area of the premises situated on the ground floor of the building, as
the case may be, the Tenant shall bear all the liabilities and obligations deriving herefrom, including its liability for any damage occasioned by an act of the Tenant or anyone acting on its behalf,
and the tenancy term shall commence on the aforementioned date for all intents and purposes, whether or not the Tenant appears on such date to accept possession of the premises.

	

	It
is hereby expressed that the delivery date of the premises or any part thereof pursuant to this clause and the commencement of the tenancy term shall not
be altered or affected by any postponement in the premises' actual delivery deriving from the execution of additions and alterations to the area of the premises situated on the fifth floor at the
Tenant's request as provided in clause 4(c) above.

 

	6.
	Parking Areas

	(a)
	The
Tenant and/or its employees and/or invitees may randomly use, without payment, the parking places at the Centre, so long as and to the degree that such have not been and are 

4

 

not
in future designated by the Company in its exclusive consideration for the sole use of any third party. 

	(b)
	The
provisions of sub-clause (a) above shall not be considered as imposing any obligation on the Company to make any parking places available to the Tenant and/or its employees
and/or invitees in addition to the Tenant's parking places, and the Tenant shall not have any claims vis-a-vis the Company in the event that it is not possible for it to use any parking places over
and beyond the Tenant's quota of parking places.

	(c)
	The
Company undertakes to prepare one parking place in addition to the parking places presently existing at Matam for every 80 square metres of the premises. Of the parking places
prepared as aforesaid, the Company shall allot the Tenant 10 designated parking places at a range of 150 metres from the building. The Company shall be entitled to alter the location of the
aforementioned parking places and to allot the Tenant other parking places, on the same terms and conditions, in its discretion.

 

	7.
	The Rent

	(a)
	Without
derogating from the provisions of clause 5 above regarding the premises' delivery date, it is hereby agreed that in consideration for the premises' rental the Tenant shall,
commencing from 1st July 1996 and thenceforth, pay the Company monthly rent in respect of the premises in an amount in shekels equal to US$12.74 (twelve US dollars and seventy four cents) per
each square metre of the premises (hereinafter referred to as "the rent"), together with due VAT.

	

	Without
derogating from the provisions hereof and for the clarification of matters, the parties hereby warrant that in accordance with the agreement
executed between them regarding the rental of an area in the building known as building 8/1 in the Centre, the Tenant shall pay the Company rent and the other payments (as prescribed in the agreement
executed between the parties regarding the premises in building 8/1) in respect of the premises in building 8/1, and such being until 30th June 1996 inclusive.

	(b)
	The
rent vests with the Tenant with the right to make reasonable use of the Centre's existing infrastructure, including: roads, pavements, gardening, lighting, signposting, parking
(subject to the provisions of clause 6 above), fences, sewerage lines and water lines. The Tenant's employees and all its successors and assigns shall be entitled to enter the area of the Centre
and/or the premises without payment.

	(c)
	The
rent shall be paid on the 1st of every month for the current month, against a due tax invoice which the Company shall furnish to the Tenant. The said rent shall be linked as
follows:

	(1)
	until
the end of the tenancy term, the monthly rent for the rental of the first 1,330 square metres of the area of the premises shall be linked to the representative rate of the
dollar known on the date of payment, together with linkage to the CPI index;

	(2)
	the
monthly rent for the balance of the area of the premises, i.e. 316 square metres, shall, for the duration of the tenancy term, be linked to the Consumer Price Index in Israel,
with the base rate of exchange of the dollar being NIS 3.11 per US$1.

	(d)
	The
index linkage shall be computed as follows:

	(1)
	If
on any date on which the rent (or any part thereof) is actually paid it transpires that the new index (as defined below) on the date of effecting the said payment is different from
the base index (as defined below), the Tenant shall effect the said payment to the 

5

 

Company
with it being altered pro rata to the rate of the change in the new index vis-a-vis the base index, i.e. multiplied by the new index and divided by the base index. 

	(2)
	"The
base index" means the American CPI index for February 1996 as published on 15th March 1996 or the Consumer Price Index for February 1996 (131.7 points, as
the case may be, in accordance with the provisions of sub-clauses (c)(1) and (c)(2).

	(3)
	"The
new index" means the American CPI index or the Consumer Price Index, as the case may be, last known at the time of actually effecting any payment of the rent or part thereof.

	(e)
	It
is hereby agreed between the parties that:

	(1)
	in
the period between 1st July 1996 and 31st December 1996 (i.e. a period of six calendar months), and in this period alone, the Tenant shall be given a discount on the rent
prescribed in clause 7(a) in an amount of US$1.41 (one dollar and forty one cents) for each square metre of the premises.

	

	In
addition to the discount mentioned in this sub-clause (e), the Tenant shall be given an additional monthly discount on the rent in an amount in shekels
equal to US$7,500 (seven thousand five hundred US dollars) for each month, and such being in the period between 1st July 1996 and until the end of December 1996, and in this period
alone.

	

	The
value of the discount in shekels shall be computed pursuant to the representative rate of the dollar on the date of setting off the discount from the
rent.

	

	The
said discounts shall be given by setting off the amount of the discount from the rent which the Tenant is liable to pay the Company in respect of the
period mentioned in this clause (e).

	(2)
	On
1st April 1997 the Tenant shall pay the Company a supplement to the monthly rent which it is liable to pay the Company in respect of April in an amount in shekels
equal to US$19,000 (nineteen thousand US dollars) in accordance with the representative rate of the US dollar on the actual payment date.

	

	It
is further hereby agreed that in the period between 1st January 1997 and 15th May 1999, the monthly rent which the Tenant is liable to pay
the Company as prescribed in clause 7(a) above shall be raised by 63.95 cents for each square metre of the premises.

	(f)
	Any
amount which the Tenant is liable to pay the Company pursuant hereto which the Tenant does not pay on time shall, commencing from the date prescribed for the payment thereof
pursuant hereto and until its actual payment, bear interest at a rate equal to that customary at Bank Leumi Le-Israel Ltd in respect of unauthorised overdrafts.

	(g)
	Payment
of the rent and of any payment and/or obligation of the Tenant to the Company pursuant hereto shall be effected by cheque or by way of bank transfer to the Company's account,
the details whereof are as follows:

	

	account
no. 9666 at Bank Hapoalim, Hatishbi Branch (709).

 

	8.
	Provision of Services

	(a)
	The
Tenant's signature hereof shall constitute and be deemed its signature on the agreement between the Company and the Centre's tenants regarding the Centre's services
company—Shatam Haifa Ltd (hereinafter referred to as "Shatam") also in respect of the premises the subject hereof. This clause shall also be deemed an agreement in favour of a third party. 

6

 

	(b)
	In
addition to the rent, the Tenant shall, commencing from the delivery date, pay Shatam, subject to the performance of Shatam's material obligations towards it by virtue of the
agreement mentioned in sub-clause (a) above, its part of the payments as in force from time to time and applying to the Centre's tenants, including the participation fees towards the Centre's
services charged by Shatam and/or any of its successors and assigns, as determined from time to time by the Company and at the times prescribed by it from time to time.

	(c)
	The
Tenant warrants that the liability to provide the services at the Centre rests with the services company, i.e. Shatam, and/or any of its successors and assigns, and that the
Company and/or the Haifa Economic Co. Ltd and/or Matam shall not bear any liability and the Tenant shall not have any complaint and/or claim against the Company in respect of any malfunction,
disturbance, inconvenience, damage or expense occasioned to the Tenant as a result of the non-provision and/or in respect of the defective provision of the said services and/or any of them.

	(d)
	The
Company warrants that a clause similar to this clause 8 exists in all the tenancy agreements executed between the Company and the companies renting areas in the Centre.

 

	9.
	Taxes, Levies and Compulsory Payments

	(a)
	In
respect of the tenancy term, the Tenant shall bear and pay the business tax if existing in respect of the plant that shall be managed in the premises, and it shall pay and/or
reimburse the Company, if the Company pays in its stead, save for property tax and/or taxes and/or levies and/or official fees obligation for the payment whereof is imposed on the owners of the land
pursuant to law, all the other taxes, levies and compulsory payments whatsoever applicable and/or which shall be applicable to the plant and/or the premises in respect of the proportional part of the
Centre and/or the Tenant (including the Tenant's parking places) and/or in connection therewith, including, but not only, the payment of rates, official fees and routine charges for sewerage, water,
electricity, telephone and the like, and it shall furnish the Company with appropriate certificates in respect of the said payments immediately upon first being requested to do so or reimburse the
Company as aforesaid the payments which the Company has paid in its stead within seven days of the request, against the Company furnishing payment references to the Tenant and provided that prior
notice is sent to the Tenant of the Company's intention to effect payment/s as aforesaid in the Tenant's stead. 

7

  

	(b)
	Value
added tax and/or any other tax applicable to possessors in accordance with the law, as shall be from time to time, is not included in the rent, and it shall be borne and paid by
the Tenant together with any payment in respect whereof it is applicable, against the production of an appropriate tax invoice.

	(c)
	For
the avoidance of doubt, the Tenant hereby confirms that any depreciation deductions in respect of the building and/or the premises, as shall be from time to time, shall be to the
credit of the Company alone, save for improvements in the premises effected by the Tenant and at its expense, the Tenant's equipment and the chattels belonging to it.

	(d)
	In
addition to the rent and the other payments which the Tenant is liable to pay the Company as provided herein, the Tenant hereby undertakes to pay the Company the payments specified
below:

	(1)
	An
amount in shekels equal to US$30,000 (thirty thousand US dollars) was paid by the Tenant to the Company in two equal payments (i.e. an amount of US$ 15,000 in each payment), the
first on 4th April 1996 and the other within 30 days of the delivery date of the premises situated on the fifth floor of the building (15th July 1996).

	

	The
aforementioned payment is in respect of the Tenant's share of the expenses of executing the finish works on the area of the premises, and it was paid
against the production of an invoice. The amount which the Tenant paid the Company was computed pursuant to the representative rate of the dollar on the date of actually effecting each payment.

	(2)
	An
amount in shekels equal to US$31,666 (thirty one thousand six hundred and sixty six US dollars) was paid by the Tenant to the Company by 23rd May 1996, and such being as the
Tenant's participation towards the expenses of planning the area of the premises. The payment was effected against the production of receipts and/or invoices attesting to the aforementioned expenses.

	(e)
	On
4th June 1997 the Tenant gave the Company a deposit in an amount in shekels equal to US$49,000 (forty nine thousand US dollars) pursuant to the representative rate of the US
dollar known on the date of giving the deposit (hereinafter referred to as "the deposit").

	

	It
is hereby expressly agreed that the Tenant may instruct the Company in writing to set off from the deposit monies payment of the rent supplement in an
amount of US$19,000 (nineteen thousand US dollars) which the Tenant is liable to pay the Company on 1st April 1997 (as prescribed in clause 7(e)(2) above) as well as the monthly rent which the
Tenant is liable to pay the Company commencing from 1st April 1998 and thenceforth.

 

	10.
	Collaterals

	

	To
secure the performance of all its obligations the subject hereof, the Tenant shall, upon the execution hereof, give the Company the following
collaterals:

	(a)
	A
promissory note in an amount of $40,000 (forty thousand US dollars) made out in blank to the order of the Company, payable upon demand, signed by the Company (hereinafter referred
to as "the note"), guaranteed by the Tenant's parent company Zoran Corporation. The amount fixed in the note shall be linked to the index in the manner provided in clause 7(d) above and the following
provisions shall apply in respect thereof:

	(1)
	the
Company may present the note for payment, in whole or in part, for the purpose of performing any of the Tenant's obligations pursuant hereto, and such being after seven days'
prior written warning; 

1

 

	(2)
	for
the purpose of presenting the note, the Company may fill in and complete the missing details and/or add any detail necessary for the purpose of presenting them
[sic] for payment;

	(3)
	the
Tenant hereby warrants and confirms that it agrees to the note's presentation for payment as provided and that it shall not have any claim and/or complaint regarding the validity
of the note and/or the manner of filling in the note's missing and/or additional details and/or in respect and/or in consequence of their [sic] presentation for payment;

	(4)
	if
the note is presented for payment, in whole or in part, the Tenant undertakes to deposit with the Company, within seven days of its payment date, a new note in the amount paid up
as aforesaid;

	(5)
	the
Tenant undertakes to advise the note's guarantors of the provisions of this clause prior to their signing the note.

	

	If
one of the note's guarantors becomes bankrupt and/or goes into receivership and/or is wound up, the Tenant shall furnish an alternative guarantor to the
Company's satisfaction within seven days of the aforementioned incident;

	(6)
	if
the tenancy comes to an end and the note has not been presented for payment, it shall be returned to the Tenant within 90 days, provided that it has complied with all its
obligations pursuant hereto.

	(b)
	The
guarantee of the parent company Zoran Corporation for the performance of all the Tenant's obligations pursuant hereto and for the indemnification of the Company in respect of any
expenses and damages occasioned to it in consequence of a breach hereof by the Tenant in the form of wording acceptable to the Company and annexed as appendix "F/1" hereto, and such being immediately
upon receipt of the Company's written request.

	(c)
	It
is expressly agreed that the delivery of the aforementioned guarantees and/or note to the Company and/or their presentation for payment by the Company shall not prejudice the
Company's right to collect from the Tenant in any other manner possible any debt and/or full compensation in respect of the damages occasioned to it in consequence of a breach of any of the Tenant's
obligations pursuant hereto and/or grant the Tenant any right and/or deprive the Company of any additional or other remedy to which it is entitled pursuant to any law and/or agreement.

 

	11.
	Liability

	(a)
	The
Tenant alone shall be liable vis-a-vis Matam and/or any third party, as the case may be, for any injury, loss or damage to person or property (and without derogating from the
generality of the aforegoing, including the property of the Tenant, its employees and guests) occurring or occasioned in the area of the premises and/or the Centre in consequence of an act and/or
omission of the Tenant and/or anyone acting on its behalf and/or Matam and/or anyone acting on its behalf, and such liability shall not be borne by Matam, subject to the following provisions.

	

	For
the avoidance of doubt, it is hereby expressed that the Tenant's liability as provided above in this clause, insofar as it relates to any act or
omission of Matam and/or those acting on its behalf, is limited to an act or omission of Matam and/or those acting on its behalf in the premises (save for damage occasioned by Matam and/or those
acting on its behalf maliciously) and shall be in accordance with that defined under the third party liability insurance policy as provided in clause 12(c)(3) below, with it being limited to an
amount of up to one million US dollars per event and in total for the entire insurance term. 

2

 

	(b)
	Notwithstanding
the provisions of sub-clause (a) above, the Tenant alone shall be liable for any damage whatsoever that shall be occasioned:

	(1)
	to
contents of the premises brought onto the premises by the Tenant and/or anyone acting on its behalf;

	(2)
	to
the premises' structure, with the exception of those risks in connection with the premises' structure which may not be insured on the Israeli insurance market, save for reasonable
wear and tear and save for damage in consequence of acts of terror and/or war.

	(c)
	If
a third party claim is filed against Matam in respect of damage for which the Tenant is liable pursuant to this clause 11, the Tenant shall be liable to indemnify Matam, within
seven days of the date on which the Company is requested to pay the said amount, in respect of any amount which Matam is held liable to pay a third party in consequence of a final court judgment,
together with all Matam's expenses in respect of conducting the trial with the third party, and without prejudice to the generality of the aforegoing the principal, interest, linkage, advocates'
professional fees, official fees, trial costs, VAT and any other expenses deriving from the claim.

	

	Indemnity
of the Company by the Tenant shall be conditional upon the Tenant being sent notice regarding the existence of the proceedings against the Company
and upon the Tenant being given the opportunity to defend itself against the claims raised within the framework of the aforementioned proceedings.

	(d)
	The
provisions of this clause 11 do not refer to damage occasioned as a result of a latent defect in the premises which could not be detected in inspections carried out by the Tenant
and/or anyone acting on its behalf and/or on reasonable inspection.

	(e)
	The
sub-clauses of this clause supplement and do not derogate from each other.

	(f)
	It
is not the intention of this clause, with all its sub-clauses, to create rights in favour of any third party, save for Matam as defined in clause 12(n) below.

 

	12.
	Insurance

	(a)
	Without
derogating from the Tenant's obligations pursuant hereto and pursuant to law, prior to the date of commencement of the Tenant's business in the premises or prior to the date
of placing any assets in the premises—whichever is the earlier—the Tenant undertakes to take out and maintain, at its expense and liability, so long as this agreement is in
force, the insurances detailed below in this clause (which shall hereinafter be called "the premises' insurance") with a duly authorised insurance company.

	(1)
	Insurance
of the premises' contents, the equipment serving the premises which the Tenant owns and/or for which it is responsible and which is situated outside the premises in the area
of the plot, and any repair, alteration, improvement, renovation and addition to the premises effected and/or that shall be effected by the Tenant and/or for it, and any furniture, equipment,
installations and inventories, against loss or damage in consequence of fire, smoke, lightning, explosion, earthquake, riots, strikes, malicious damage, flood, storm and tempest, damage by a vehicle,
damage by an aircraft, water damages, electrical damages and break-in.

	(2)
	Insurance
against loss of profits and consequential damage to the Tenant, in appropriate amounts and for an appropriate indemnity period, as a result of loss or damage to the Tenant's
property and/or the premises' contents and/or the premises' structure. 

3

 

	

	It
is hereby agreed that the Tenant may refrain from taking out loss of profits insurance as aforesaid, but in such case Matam shall not bear any liability,
and the Tenant does and shall not have any complaint and/or demand and/or claim against it, as if the insurance had been taken out as aforesaid.

	

	The
Tenant undertakes to procure that the policy mentioned in sub-clauses 12(a)(1) and (2) includes an express condition pursuant whereto the
insurer waives any right of subrogation vis-a-vis Matam and all those acting on its behalf, vis-a-vis the other tenants and residents of the building (if there is a parallel condition in their
policies of the insurer's waiver of any right of subrogation vis-a-vis the Tenant) and vis-a-vis all the successors and assigns of the parties mentioned above, save for damage occasioned with
malicious intent.

	(3)
	Third
party liability insurance with a limit of liability not less than an amount in shekels equal to US$1,000,000 (one million US dollars) per event. This insurance is not subject to
any restriction regarding liability deriving from fire, explosion, panic, lifting, loading and unloading instruments, defective sanitary installations, poisoning, any harmful substance in food or
beverage and any claims by the National Insurance Institute. The insurance shall be extended to indemnify Matam in respect of its liability for the Tenant's acts and/or omissions, and in respect of
its liability in the area of the premises alone by virtue of its being the owner of the premises and the provider of services in respect thereof.

	(4)
	Employers'
liability insurance in respect of the Tenant's liability vis-a-vis all those employed by it and on its behalf with the highest limits of liability customary on the Israeli
insurance market at the time of taking out the insurance and/or on the date of its renewal.

	

	This
insurance shall not include any restriction regarding contractors, sub-contractors and their employees, baits and poisons and regarding the employment
of youth.

	

	The
said insurance shall be extended to indemnify Matam in the event that it is deemed as the employer of the Tenant's employees or any of them.

	(b)
	The
Tenant undertakes to update the insurance amount in respect of the insurance taken out pursuant to clause 12(a)(1) above from time to time, so that it always reflects the full
value of the property insured pursuant thereto.

	

	The
Tenant undertakes to use the monies received from the insurance company pursuant to the insurance mentioned in clause 12(a)(1) above solely for
the immediate restoration of the damages the subject of the said insurance.

	(c)
	The
Tenant warrants that it shall not have any complaint and/or demand and/or claim against Matam for damage in respect whereof it is entitled to indemnity under the insurance taken
out pursuant to clauses 12(a)(1) and 12(a)(2) above, and it hereby exempts Matam from any liability for such damage.

	(d)
	Without
the need for any request by the Company, the Tenant undertakes, no later than the date of commencing the Tenant's business in the premises or prior to the date of placing any
assets in the premises, whichever is the earlier, to furnish the Company with a certificate regarding the taking out of the premises' insurance in accordance with the form of wording in the
"Certificate of the Premises' Insurances" (annexed hereto and marked as appendix "F"), duly signed by the insurer.

	

	The
Tenant warrants that it is aware that the furnishing of the "Certificate of the Premises' Insurance" as aforesaid is a suspensory condition and
condition precedent for the delivery of possession of the premises and/or the placing of any assets in the premises, and the Company 

4

 

shall
be entitled to prevent the Tenant from commencing its business in the premises and/or from placing assets as aforesaid if the said certificate is not furnished prior thereto and at the time
indicated above. 

	(e)
	For
the avoidance of doubt, it is expressed that the failure to furnish the insurance certificates on time as provided in clause 12(d) above shall not affect the Tenant's
obligations pursuant hereto, including, and without prejudice to the generality of the aforegoing, any payment obligation applicable to the Tenant, and the Tenant undertakes to perform all its
obligations pursuant hereto even if it is prevented from executing works and/or receiving possession of the premises and/or placing assets in the premises and/or commencing its business in the
premises as a result of the failure to furnish the certificates on time.

	(f)
	The
Tenant undertakes to comply with the terms and conditions of the policies, to pay the insurance fees in full and on time, and to procure and ascertain that the premises' insurance
policies are renewed from time to time as necessary and are valid for the duration of the tenancy term.

	(g)
	No
later than 14 days prior to the end of the term of the premises' insurances, the Tenant undertakes to deposit a certificate with the Company of the taking out of insurance as
provided in clause 12(f) above in respect of an extension of their validity [sic] for an additional year and within 30 days of the renewal of the insurance as aforesaid
the Tenant shall deposit the original copies of the premises' insurances. The Tenant undertakes to redeposit a certificate of the taking out of the insurance, at the times fixed, each insurance year
so long as this agreement is in force.

	(h)
	The
Tenant warrants and undertakes that the Company's right to review and inspect the insurance certificates and to instruct alterations does not impose any liability and/or
responsibility upon the Company and/or anyone acting on its behalf in respect of the nature and scope of the said insurance certificates and policies or in respect of their absence, and does not
derogate from any obligation imposed upon the Tenant pursuant hereto.

	(i)
	The
Tenant undertakes not to do and/or permit others to do any act or omission in the premises and/or the building which is likely to cause an explosion and/or conflagration and/or
which might increase the insurance expenses for which Matam and/or the other tenants are liable in respect of the insurance of the building or the premises situated therein.

	(j)
	Without
derogating from the Tenant's obligations pursuant hereto and pursuant to any law, Matam shall purchase and maintain, for the duration of the tenancy term, all or any of the
insurance policies specified below, in its exclusive discretion:

	(1)
	employers'
liability insurance—for the insurance of Matam's liability vis-a-vis its employees pursuant to the Civil Wrongs Ordinance (New Version), in respect of any
bodily injury to an employee during and in consequence of his employment in the building and/or its surroundings;

	(2)
	third
party liability insurance—for the insurance of Matam's and the Tenant's liability vis-a-vis any third party within the common areas, with limits of liability that
shall not be less than US$1,000,000 (one million US dollars) per event and in total for the insurance term.

	

	The
policy shall include a "cross liability" clause.

	

	For
the avoidance of doubt, the policy shall not insure the Tenant's liability in respect of bodily injury and/or damage to property in the premises and/or
the rented areas and/or the areas designated for rental in the building; 

5

 

	(3)
	property
insurance—insurance of the building and any other property belonging to Matam in the area of the building and its surroundings, against loss or damage in
consequence of the following risks: fire, explosion, earthquake, storm, tempest, flood, water damages, aircraft, collision, strikes, riots, malicious damage, break-in, glass breakage and any further
risk necessary in the opinion of the Company and/or the management company.

	

	The
said insurance shall include a clause regarding waiver of the right of subrogation vis-a-vis the Centre's tenants in respect of damage unintentionally
occasioned by them to the building. For the purpose of this clause, the expression "building" shall include all the systems comprising an integral part of the building, and shall expressly not include
the contents of the building's rented areas and any addition, improvement or extension effected to the building's rented areas by or for the tenants;

	(4)
	insurance
against loss of rent occasioned to Matam by reason of damage caused to the premises' structure or by reason of the destruction of the premises' structure as a result of the
risks specified in clause 12(j)(3) for an indemnity period of 12 (twelve) months.

	(k)
	The
Company shall furnish the Tenant with a certificate of the existence of the insurances specified in clause 12(j) within seven days of the parties' execution hereof.

	(l)
	The
following provisions shall apply to the policies mentioned in clause 12(j) above:

	(1)
	Matam
is entitled from time to time to alter and/or cancel and/or replace the policies and/or to take out additional insurances, all in its exclusive discretion;

	(2)
	the
policies shall be made available for the Tenant's inspection at the Company's offices by prior coordination. The Tenant may, at its expense, purchase any other, additional or
supplementary insurance besides the aforementioned policies in its discretion, if the aforementioned policies are not to its full satisfaction or do not, in its opinion, meet the needs of the
structure and/or the premises;

	(3)
	the
Tenant undertakes to meticulously and fully comply with all the provisions of the policies in order to preserve the rights of Matam, the management company and the other tenants
within the framework of the policies;

	(4)
	the
Tenant shall cooperate with Matam in the event that a claim is submitted to the insurance company and shall immediately furnish any document, testimony and the like required for
the purpose of submitting the claim.

	(m)
	The
Tenant warrants that it shall not have any complaint and/or demand and/or claim against Matam in respect of any damage for which it is entitled to indemnity (or for which it would
be entitled to indemnity were it not for the excess fixed in the policy) under the insurances taken out pursuant to clause 12(a) above, and it hereby exempts Matam from any liability for such
damage. As aforesaid, the provisions of this clause shall add to (and not derogate from) any other provision hereof regarding exemption from liability vis-a-vis Matam.

	

	Furthermore,
the Tenant exempts the other tenants and residents in the building from any liability for damage as aforesaid, provided that the tenancy
agreements or any other agreement vesting them with rights in the building include a parallel clause regarding exemption from liability in favour of the Tenant.

	(n)
	In
clause 11 above and in this clause 12, the following expressions shall bear the following meanings:

	(1)
	"damage"—as
defined in the Civil Wrongs Ordinance, including indirect damage, derivative damage, consequential damage, loss of income and damage to goodwill; 

6

 

	(2)
	"Matam"—Matam
Science Industries Centre Haifa Ltd, the Haifa Economic Co. Ltd, Haifa Municipality and Shatam Haifa Ltd.

	

	The
Company shall be the agent for all the entities mentioned in this sub-clause (n) insofar as the provisions of this clause are concerned.

 

	13.
	Transfer Or Charge of Rights and Right of Pre-emption

	(a)
	The
Tenant's rights by virtue hereof may not be howsoever charged, in whole or in part.

	(b)
	The
Tenant may not howsoever transfer and/or assign its rights and/or obligations pursuant hereto or any of them to another or others (for consideration or otherwise), unless it has
received the Company's prior written consent thereto. The Company shall not withhold its consent on unreasonable grounds. In any event of a transfer of rights and/or obligations, the Tenant shall
remain liable for the performance of its obligations pursuant hereto.

	

	Notwithstanding
the above provisions of this sub-clause (b), it is agreed that the Tenant may assign its rights pursuant hereto to its parent company, Zoran
Corporation, whose registered office is located at 2041 Mission College Boulevard, Santa Clara, California 95054, USA (hereinafter referred to as "the parent company"), subject to all the terms and
conditions specified below:

	(1)
	the
Tenant shall send the Company at least two months' prior written notice of its intention to assign its rights to the parent company;

	(2)
	from
the assignment date the parent company shall be liable for the performance of all the Tenant's obligations pursuant hereto, and for the performance of all the Tenant's past
obligations if and insofar as such have not been performed by it;

	(3)
	without
derogating from the above provisions of sub-clause (b)(2), it is hereby expressed that the assignment of the Tenant's rights to the parent company shall not howsoever derogate
from the Tenant's obligations pursuant hereto until the assignment date and/or shall not derogate from and/or constitute a waiver by the Company of any complaint and/or right available to the Company
pursuant hereto and/or pursuant to any law;

	(4)
	the
parent company shall, prior to the date of assignment of the Tenant's rights and as a condition therefor, give the Company, for the purpose of securing the performance of all its
obligations pursuant hereto, an autonomous bank guarantee to the Company's satisfaction in an amount of US$90,000 from a bank that shall be approved by the Company in advance and in writing.

	

	The
guarantee shall be valid until 90 days have elapsed from the end of the tenancy term. The aforementioned bank guarantee shall replace the promissory
notes given by the Tenant to the Company in accordance with the provisions hereof.

	(c)
	The
Company may transfer and/or assign and/or charge its rights and/or any of them pursuant hereto (including the ownership of the premises) to another or others without requiring the
Tenant's consent, provided that the Tenant's rights pursuant hereto are not prejudiced.

	(d)
	In
order to clarify matters, its is agreed and warranted by the parties that the rights to build on the roof of the building shall belong to the Company alone, and the Tenant hereby
grants its consent to building on the roof of the building as the Company decides from time to time, provided that such does not disturb, to the extent possible, the Tenant's ordinary operations in
the premises.

	

	Notwithstanding
the aforegoing, the Company warrants that it shall not build on the building's roof until May 1999. 

7

 

	14.
	Provisions Regarding The Use of The Premises

	(a)
	The
Tenant may use the premises solely for the purpose of conducting its business and not for any other object.

	

	Furthermore,
the Tenant confirms that it is aware that another tenant (other tenants) shall use the common area of the premises and the building, and the
Tenant undertakes not to prevent such tenant (or tenants) from making reasonable use of the common area, including the grant of access to the common area, as necessary.

	

	The
Company hereby confirms that its tenancy agreements with the tenants of the Centre and the building contain clauses similar to sub-clauses (a) to
(l) below.

	(b)
	The
Tenant shall procure that the plant shall function in accordance with the custom in the Centre and the Tenant shall obey and comply with all the instructions given to it from time
to time by the Company and/or Shatam in connection with the rules of conduct therein. The Tenant shall ascertain and ensure that its employees and/or successors and assigns also act pursuant to
the provisions of this clause.

	(c)
	

	(1)
	The
Tenant may not execute alterations and/or install anything in the premises, save for minor alterations that do not amount to rigid construction, unless it obtains the Company's
prior written consent thereto and pursuant to terms and conditions that the Company shall determine. The Company shall not refuse the execution of such alterations and repairs, save on reasonable
grounds.

	

	Any
structural alteration executed in contravention of the provisions of this sub-clause shall be removed by the Tenant at its expense immediately upon
receipt of the Company's request to do so, whether during the tenancy term or thereafter. If the Company approves an alteration as aforesaid, such alterations and/or installations shall be removed
from the premises, at the Company's request, at the end of the tenancy term, at the Tenant's expense, in order that the premises be restored to the Company in their original condition. If the Company
does not request removal as aforesaid and the Tenant decides to leave the alterations and/or installations, the aforementioned alterations and/or installations shall remain owned by the Company, and
the Tenant shall not be entitled to request any compensation in respect thereof.

	(2)
	Any
alterations and/or installations executed in the premises in accordance with the provisions of sub-clause (c)(1) above shall be effected by the Tenant at its full expense
and liability, and the Company shall not be howsoever liable as landlord and/or owner.

	(d)
	The
Tenant shall maintain order and cleanliness in the premises and shall comply with all the instructions of the Company, Shatam and the municipal by-laws in connection with the
cleaning arrangements, the manner of disposing of garbage and waste and maintaining the proper working order of the building's drainage and sewerage system. The failure to give instructions as
aforesaid shall not release the Tenant from its obligations pursuant to this clause.

	(e)
	The
Tenant warrants that it is presently in possession of, or will obtain by the commencement of the tenancy term, all the approvals and licenses necessary for the management of the
plant and/or the use of the premises in accordance with the provisions hereof and the provisions of any law, and that it shall, pursuant to the provisions of the law and the regulations in connection
therewith, keep and always be equipped with appropriate valid licenses and approvals in respect of any activity connected with the management of the plant and/or the use of the premises which require
approval or a license pursuant to law. 

8

 

	

	The
failure to obtain the said licenses and/or any of them shall not constitute a cause for the termination hereof and/or for the non-performance of the
Tenant's obligations pursuant hereto and in particular for non-payment of the rent and the other payments pursuant hereto.

	(f)
	The
placing of any sign or advertising means or other display on behalf of the Tenant on the premises' external walls or in the building's common areas or in the vicinity thereof
shall require the Company's prior written approval.

	(g)
	In
addition to the provisions of clause 8 above and in addition to all the payments for which the Tenant is liable pursuant hereto, the Tenant shall pay the Company for the costs of
maintaining the common areas of the building, including the dining room costs, all as provided in appendix "I" hereto which constitutes an integral part hereof.

	(h)
	The
Tenant shall comply with the instructions of the Company and any other competent authority in connection with fire extinguishing and fire prevention arrangements and procedures,
the Civil Defence, safety and security, and shall purchase and/or install, at its expense and by prior written coordination with the Company, pursuant to the instructions of the above entities, all
the preventative and safety equipment required for the application and maintenance of the above instructions. The equipment shall remain owned by the Tenant which may remove it from the premises at
the end of the tenancy term and it shall do so if requested by the Company. 

9

  

	(i)
	Disturbances, Avoidance of Nuisances and Preservation of the Environment

	(1)
	The
Tenant shall manage the plant and use the premises by refraining from bothering neighbours and by refraining from creating a nuisance in the premises or its surroundings and all
in accordance with the practice in the building and/or the Centre and/or with the Company.

	(2)
	The
Tenant hereby confirms that its plant does not constitute an ecological hazard and that it shall not constitute such during the tenancy term pursuant hereto.

	(3)
	Without
derogating from all the above provisions, the Tenant shall act and instruct its employees and anyone acting on its behalf to act in accordance with the provisions of the
Abatement of Nuisances Law, 5721-1961 and the Maintenance of Cleanliness Law, 5744-1984 and all the regulations and orders thereunder and of all the by-laws of the Haifa Municipality and the local
authority.

	(j)
	The
Tenant undertakes to refrain from any act or omission in the premises, and to refrain from permitting an act or omission by another or others in the premises, which is likely to
impose liability upon the Company pursuant to law, including damages to person and/or property.

	(k)
	The
Tenant shall totally refrain from taking any possession of the common area.

 

	15.
	Warranty for the Quality of the Buildings and the Premises

	(a)
	The
Company shall, within the framework of the warranty of the contractor which built the premises for it (hereinafter referred to as "the contractor"), be liable to repair the
defects and/or faults detected and/or arising in the premises within one year of the delivery date (hereinafter referred to as "the warranty period") and deriving from defective work and/or the use of
defective materials. The Tenant must notify the Company in writing of any such defect immediately upon its detection.

	

	If
the Tenant does not notify the Company of defects at the aforesaid time, such shall be deemed confirmation on its part that there were no such defects in
the premises.

	(b)
	If
the Tenant notifies the Company after the end of the warranty period of a defect in respect whereof the Company has a warranty from the contractor which executed the work in the
premises for a period longer than the warranty period as defined in sub-clause (a) above, the Company shall exercise its right pursuant to the aforementioned warranty, such that the performing
contractor shall repair the defect, and such being without recognising any obligation and/or liability on the Company's part.

	

	The
Company shall act to the best of its ability in order to realise the contractors' full liability towards it as provided in sub-clause (a) above
and in this sub-clause.

	

	If
the parties decide to enable the Tenant to exercise the Company's rights pursuant to the contractor's warranty as provided above, the Company shall
assign all its rights pursuant to the agreement between it and the contractor, and the Tenant for its part may not have recourse to the Company for any reason. The Company may not refuse to assign its
rights as aforesaid, save on reasonable grounds.

	(c)
	The
Tenant shall be liable, at its expense, for the routine maintenance of the premises and their systems, including the air conditioning systems, and shall, at its expense, repair
all the routine faults discovered in the premises, as speedily as possible in the circumstances of the case. 

1

 

	(d)
	Without
derogating from the aforegoing, the Tenant shall use the premises with appropriate care, maintain them in good and proper condition (including whitewashing and painting)
throughout the tenancy term and effect, without delay and at its expense, all the repairs necessary in order to perform its obligation pursuant to this clause.

	(e)
	If
the Tenant and/or the Company do not perform their obligations as provided above in this clause, the second party may (but is not obliged), after giving the other party ten days'
prior written notice during which the obligation is not performed or the performance thereof is not commenced, itself perform the maintenance and repairs for which the other party is liable, and the
Tenant or the Company, as the case may be, shall reimburse the second party with all the expenses incurred by it for such purpose, immediately upon its first demand and in accordance with the
provisions of such request.

 

	16.
	Non-Applicability of The Tenants' Protection Laws

	

	The
parties hereby warrant that:

	(a)
	the
construction of the building and the premises was completed after 5728-1968 and that the Tenants' Protection Law (Consolidated Version), 5732-1972 shall not apply to the tenancy
by virtue hereof, or at all;

	(b)
	no
key money or other similar payment has been or shall be paid to the Company or any other person and such has not been nor shall be received from the Tenant in consideration for the
delivery of use of the premises and everything connected therewith;

	(c)
	the
Tenants' Protection Law (Consolidated Version), 5732-1972 and/or any other law for the protection of tenants presently existing or which shall be promulgated in the future shall
not apply in respect of this agreement and to the parties' relations by virtue hereof.

 

	17.
	Right of Entry to The Premises

	

	The
Company's representatives shall have a right of entry to the premises (subject to security restrictions) during reasonable hours and by prior
coordination with the Tenant in order to ascertain the degree to which the provisions hereof are being performed and/or in order to show the premises to others and/or in order to do the acts and take
the steps prescribed herein or in any law and obliging entry to the premises, provided that any damage occasioned to the Tenant as a result of its refusal to permit entry in the said cases and for the
said objects or its refraining from coordinating entry as aforesaid to the premises shall be borne by the Tenant alone, and the Tenant shall not have any complaint and/or claim against the Company by
reason thereof.

	

	The
Company shall act to the best of its ability to ensure that the disturbance to the Tenant shall be as minor as possible and that the premises are
restored to their previous condition as soon as possible and insofar as possible.

	18.
	Vacation of The Premises

	(a)
	No
later than the date on which the tenancy term comes to an end, the Tenant shall vacate the premises and return possession thereof to the Company, with them being vacant of any
person and object (save for equipment and accessories belonging to the Company) and in good and proper condition as delivered to the Tenant, save for reasonable wear and tear.

	(b)
	In
respect of and for each day of delay in returning possession of the premises contrary to the provisions of sub-clause (a) above, the Tenant shall pay the Company the full
month's rent for the last month of the tenancy term divided by 10 together with due VAT. This payment, which shall be deemed pre-agreed liquidated damages, shall not derogate from any other remedy to
which the Company is entitled pursuant to any law and/or agreement. 

2

 

	(c)
	On
the vacation date, the representatives of the Company and the Tenant shall draw up vacation minutes which shall state the defects and repairs which the Tenant must effect in order
to restore the premises to a good and proper condition and pursuant to the timetable agreed upon.

	

	Notwithstanding
the aforegoing, Matam may effect the repairs itself and the Tenant shall reimburse Matam with the costs of effecting the repairs pursuant to
invoices submitted to it by Matam. Matam may withhold the collaterals mentioned in clause 10 until completion of the repairs by the Company and if necessary it may realise the collaterals as cover for
its aforementioned expenses.

 

	19.
	Negation of Representation, The Tenant's Employees

	(a)
	The
provisions hereof and/or the parties' conduct by virtue hereof shall not be interpreted as empowering one party to appear in the other party's name or stead, or as conferring,
pursuant to the aforesaid, the status of representative of the other party.

	(b)
	The
employees of one party shall not be deemed the employees of the other party in any circumstances and for any object.

 

	20.
	Fundamental Breach of The Agreement

	

	Without
derogating from the provisions of any law, each of the following acts or omissions shall be deemed a fundamental breach of the agreement by the
Tenant and shall serve as a cause for vacation of the premises forthwith and for their return to the exclusive possession of the Company, and all on prior written notice of 21 days, unless the
fundamental breach hereof is rectified by the Tenant to the Company's satisfaction by the date fixed in the aforementioned notice:

	(a)
	the
cessation of the Tenant's activity for a period exceeding 180 days, save in circumstances of force majeure alone, and/or the submission of an application for the Tenant's winding
up and for the appointment of a receiver over a material part of the Tenant's property, and the application or appointment, respectively, is not cancelled within 60 days;

	(b)
	a
delay in payment of the rent, including the supplemental rent, or in effecting any of the other payments for which the Tenant is liable by virtue hereof and/or the breach thereof
for a period exceeding 30 (thirty) days from the time fixed for the payment thereof, provided that the Tenant is sent notice thereof requesting that the payments be made and it does not comply
therewith within seven days;

	(c)
	the
grant of a use right or the transfer or charge of rights or any of them in contravention of the provisions of clause 14 above;

	(d)
	the
Tenant's failure to take out and/or maintain the insurance in contravention of the provisions of clause 13 above;

	(e)
	the
failure to return possession of the premises at the time, in the manner and in the condition specified herein;

	(f)
	the
grant of an order in connection with the Tenant containing an arrangement with creditors and/or an arrangement in favour of creditors and/or a receivership and/or bankruptcy
and/or winding up of any type whatsoever and/or the dissolution of business in any manner, and the order is not cancelled within sixty days;

	(g)
	the
non-performance of the obligations pursuant to the agreement between the Tenant and Matam and the failure to comply with the instructions of Shatam, the Centre's services company;

	(h)
	the
Tenant causes any nuisance pursuant to clause 15(h) hereof; 

3

 

	(i)
	effecting
alterations in the premises without obtaining the Company's prior written permission;

	(j)
	the
non-performance of the obligation to use the premises as provided in clause 15 hereof;

	

	The
provisions of this clause do not prejudice the Company's right to any other relief to which it is entitled against the Tenant pursuant to law and/or
agreement in respect of its breach.

	21.
	Early Vacation Or Abandonment

	

	If
the Tenant vacates or abandons the premises or is evicted from the premises prior to the end of the tenancy term or in the case of a breach of this
agreement without the Company's prior written consent, the Tenant shall continue paying the Company rent and all the other payments for which it is liable by virtue hereof until the end of the tenancy
term, as if it had continued to possess and use the premises. The provisions hereof shall not derogate from the Company's right to terminate the agreement on the basis of the provisions of clause 20
above.

	

	It
is agreed and warranted by the parties that this clause shall not apply in the case of force majeure as defined below:

	

	for
the purpose of this clause 21, force majeure
means:                                        
                  

	

	It
is agreed and warranted by the parties that the Tenant shall be entitled to bring an alternative tenant in its stead, provided that all the following
cumulative conditions are fulfilled:

	(a)
	the
Tenant fulfills all the terms and conditions of the agreement until the date on which the premises are actually transferred to the alternative tenant who shall be approved by the
Company as provided below; and

	(b)
	the
Company is given at least two months' prior written notice thereof; and

	(c)
	the
alternative tenant is approved by the Company, whose decision shall be exclusive and final; however, the Company shall not withhold its consent, save on reasonable grounds; and

	(d)
	the
terms and conditions of the new tenancy agreement with the alternative tenant shall be agreed between it and the Company to the Company's satisfaction, provided that they shall
not be inferior to the terms and conditions hereof; and

	(e)
	subject
to the provisions of sub-clause (d) above, the alternative tenant shall perform all the Tenant's obligations and give the Company collaterals / guarantees to its
satisfaction.

	

	The
above provisions of this paragraph do not derogate from the Tenant's obligations pursuant hereto.

 

	22.
	Self-help

	

	Wherever
an obligation is imposed on a party hereto and such party does not absolutely perform it or does not perform it properly, for any reason
whatsoever, the second party may (but is not bound to) perform or complete the performance of any such obligation itself and/or by others, within a reasonable time, and all the reasonable expenses
involved therein shall be borne by the other party. Such expenses shall be reimbursed to the second party on the production of an invoice (based on appropriate references) submitted by it to the other
party within 30 days of the invoice's submission. If the Tenant incurs any such expense, it may deduct it from the rent if it has given the Company 30 days' prior written notice thereof and the
Company has failed to indemnify it in respect of the said expense.

	23.
	Construction, Repairs, Improvements and Development Works

	

	The
provisions hereof shall not prevent the Company and Shatam from erecting installations and executing construction, repairs, improvements and development
works in the building, the 

4

 

premises,
its surroundings and/or the Centre, so long as such do not unreasonably disturb the Tenant in the management of its plant. The Tenant shall not object to the execution of the above acts and
shall cooperate with the Company and/or Shatam as aforesaid and at their expense insofar as the execution thereof is concerned. 

	

	It
is agreed that the aforementioned works shall be at the Company's liability and expense, unless the parties otherwise agree in writing.

	24.
	Evidence and Modification of The Agreement

	(a)
	Any
alteration hereto and/or modification hereof shall only be effected in an express written document that shall be signed by the parties hereto.

	(b)
	The
consent of a party hereto to a deviation from the terms and conditions hereof in a particular case or in a series of cases shall not constitute a precedent and no inference shall
be drawn therefrom in the same case and/or in any other case in the future.

	(c)
	If
a party to this agreement has not used or has delayed in using any of the rights vested in it pursuant hereto in a particular case or in a series of cases, such shall not be deemed
a waiver of any of its rights.

	(d)
	It
is agreed between the parties that the acceptance of a cheque or notes does not constitute payment, until they have actually been paid.

 

	25.
	Jurisdiction

	

	It
is agreed between the parties that any dispute and/or difference and/or judicial proceeding in connection herewith and the obligations deriving herefrom
shall be decided solely and exclusively pursuant to the Israeli law, and that the sole and exclusive place of jurisdiction is the competent court in Haifa.

	26.
	Stamp Duty

	(a)
	All
the costs of stamping this agreement and the copies hereof shall be borne and paid by the parties in equal shares.

	(b)
	Stamps
tax applicable to the collaterals mentioned in clause 9 above (including the costs of obtaining them) shall be paid by the Tenant.

 

	27.
	Confidentiality

	

	For
so long as the agreement is in force, the parties undertake to maintain confidentiality in respect of all the plans connected with the building, the
floor and its systems, with the aim of preventing any malicious sabotage of the building.

	

	Wherever
such a disclosure is obliged, the parties undertake to obtain from the person receiving the plans, save for government entities, a written
undertaking to maintain confidentiality in respect thereof and to return them when the need to continue holding them comes to an end.

	

	Furthermore,
the parties undertake to maintain confidentiality in respect of the terms and conditions hereof, save for the commercial details insofar as
such are required by an external entity or external entities or for the Tenant's activity.

	28.
	Notices and Warnings

	(a)
	Any
notice and/or warning and/or request sent from one party to the other in connection herewith shall be sent by registered mail or delivered by hand to the addresses of the parties
set forth below (or any other address of which appropriate written notice is given), and such notice or warning shall be deemed to have been delivered to the addressee upon its actual 

5

 

delivery—if
delivered by hand, and if sent by mail in Israel—at the end of 72 hours from being placed in the mail, with the postage fees having been fully paid in advance. 

	(b)
	The
addresses of the parties as aforesaid are:

	(1)
	the
Company—Matam—Science Industries Centre Ltd, Postal Agency Matam 31905 Haifa;

	(2)
	the
Tenant—at the premises.

	29.
	The
parties warrant and confirm that they have read this agreement and all the clauses and appendices hereto and they have understood the contents, nature and significance thereof and
agree to the provisions thereof. 

 
 

AS WITNESS THE HANDS OF THE PARTIES:    
    

	
 The Company	 	
 The Tenant

6

  

 
 

APPENDIX "I"
  ADDENDUM TO THE TENANCY AGREEMENT DATED    
    

	

Between:	
 	
Matam—Science Industries Centre Haifa Ltd

PC 51-068740-3

(hereinafter referred to as "the Company")
	

 	
 	
of the one part
	

And:	
 	
Zoran Micro-Electronics Ltd

PC 51-094944-9

(hereinafter referred to as "the Tenant")
	

 	
 	
of the other part
	

Whereas	
 	

the Tenant wishes the Company to manage the building's common areas (as defined below);
	

And Whereas	
 	

the Company has agreed to see to the management and maintenance of the building's common areas for the consideration and subject to the terms, conditions and provisions specified in this addendum (hereinafter referred to as "the addendum") and the
appendices hereto;
	

And Whereas	
 	

the Tenant wishes catering services to be provided in the building to its employees and guests;
	

And Whereas	
 	

the Company has agreed to assign a section of the building's common areas which shall serve as a dining room (as defined below) for the purpose of providing catering services to the companies renting areas in the building and their guests for the
consideration and subject to the terms, conditions and provisions specified in this addendum and the appendices hereto;

Accordingly, it is warranted and provided between the parties as follows:

	1.
	Recitals

	1.1
	The
recitals and appendices hereto constitute an integral part hereof.

	1.2
	This
addendum constitutes an integral part of the tenancy agreement executed between the parties
on                                         
                 (hereinafter referred to as "the agreement").

 

	2.
	Definitions

	

	In
this addendum—

	

	"The Building"—as defined in the tenancy agreement;

	

	"The Contractor"—Norcate Ltd, which has undertaken to supply catering services to the tenants in
building 30 and its guests in accordance with the terms and conditions of the agreements executed between it and each of the tenants in building 30 or any other contractor elected by the tenants in
building 30 in accordance with the terms and conditions of the agreements executed between them and the contractor;

	

	"The Tenants in Building 30"—i.e. Aurec, ABB, Madge Israel and/or anyone renting areas in the
building from the Company instead of any of them;

	

	"The Tenant's Employees"—the Tenant's employees and guests and/or anyone permitted by the
Tenant's representative (as defined below) to enter the dining room (as defined below) and to use 

1

 

the
catering services as defined below in this clause, all in accordance with the written guidelines given by the representative to the contractor; 

	

	"The Company's Representative"—anyone appointed from time to time by the Company in its
exclusive discretion to supervise and monitor the use made of the dining room;

	

	"The Tenant's Representative"—a representative appointed by the Tenant, whose position involves
the ordering of the catering services, approval of the contractor's invoices and the payment thereof, and any routine acts in connection with the catering services;

	

	"The Dining Room"—an area of approx. 315 square metres in building 30 as marked in red in
appendix "A" which is designated for the purpose of operating a dining room and the provision of the catering services as defined below, which includes a dining hall (designated to accommodate approx.
120 seats for diners) and a kitchen for heating and/or rewarming;

	

	"The Catering Services"—the preparation of meals and their service to the Tenant's employees in
the dining room in the manner, to the extent and subject to the terms, conditions and provisions provided hereinbelow;

	

	"Common Area" or "Common Areas"—as defined in
the tenancy agreement and together with the dining room as defined above;

	

	"The Routine Expenses"—expenses in respect of maintaining the common areas, including, inter
alia, the following components:

	(a)
	the
cleaning and maintenance of the common area (including the building's external walls and roof);

	(b)
	the
maintenance of the common equipment, elevators, air conditioning equipment and the like;

	(c)
	electricity
in the common area;

	(d)
	water
in the building (including water in the conveniences on all the floors);

	(e)
	the
costs of operating the dining room, including structural insurance, the maintenance of the dining room structure and rates, and save for the cost of obtaining the catering
services from the contractor for which the Tenant and all the other tenants in building 30 are solely and exclusively liable;

	

	"The Index"—the consumer price index published by the Central Bureau of Statistics and Economic
Research, including such index even if published by another government institution, whether built on the same data on which the existing index is built or not. If the index is replaced as aforesaid,
the Central Bureau of Statistics shall determine the ratio between it and the cost of living index which replaces it;

	

	"The Base Index"—the index for March 1996 which was published on 15th April 1996
and which stands at 133.0 points, save where this addendum expressly otherwise provides;

	

	"The Determining Index"—the index known on the date of actually effecting any payment;

	

	"The Proportional Part of the Routine Expenses"—the Tenant's part of the routine expenses, which
shall be computed pursuant to the proportional part rented by the Tenant in the building in relation to the total area of the building, i.e. 21.6%;

	

	"Overheads and Management Fees"—payment for the general management of the common area which
shall constitute 12% of the proportional part of the routine expenses; 

2

 
	

	"The Dining Room Expenses"—payment for the assignment of an area in the building for the
operation of the dining room and the expenses involved therein.

	3.
	Management of The Common Areas

	3.1
	The
parties hereby agree and undertake that the Company and/or someone acting on its behalf shall manage the maintenance of the common areas in the building on standards acceptable in
buildings which were constructed in the Centre, and in consideration the Tenant shall pay the Company the proportional part of the routine expenses as defined above.

	

	The
Tenant shall pay the proportional part of the routine expenses in accordance with the provisions of clause 5 below.

	3.2
	It
is hereby agreed that in addition to payment of the proportional part of the routine expenses as provided above, the Tenant shall also pay the Company, at the same times, overheads
and management fees as defined above for managing the maintenance of the common areas.

	3.3
	In
addition to and without derogating from the provisions of sub-clauses 3.1 and 3.2 above, the Tenant shall pay the Company in respect of the dining room expenses as provided below:

	3.3.1
	the
area of the premises for the purpose of paying rent for the premises each month, as prescribed in clause 1(a) of the agreement (i.e. 1,646 square metres) shall be
increased by 5.3% to 1,733 square metres, commencing from the date of the dining room's operation;

	3.3.2
	for
the avoidance of doubt, it is hereby agreed that the increase of the area of the premises as provided in sub-clause 3.3.1 above is for the purpose of charging for the dining
room expenses alone and such shall not add to and/or alter the Tenant's rights insofar as the rental of areas in the building are concerned and/or increase the actual area of the premises.

	3.4
	It
is hereby agreed between the parties that the Company's representative may permit the provision of catering services in the dining room to the employees and guests of companies
which are not renting areas in building 30 (hereinafter referred to as "the external company"), provided that prior written consent thereto is given by the tenants in building 30 together renting more
than 66% of the areas being let in the building, and subject to the external company participating in the dining room expenses at a rate determined by the Company's representative.

	

	Monies
for participation in expenses collected from the external company as provided in this sub-clause shall be distributed amongst the tenants in building
30 which participate in the dining room expenses as provided in clause 3.3 above. The distribution shall be effected pro rata to the tenants' share of the payment of the dining room expenses.

	3.5
	It
is hereby agreed that the Company and/or the Company's representative may use the dining room to hold special functions, provided that use as aforesaid may only be made by prior
coordination with Zoran in order to prevent, insofar as possible, impairment of the catering services.

	

	It
is further hereby agreed that the Tenant and/or any of the tenants in building 30 may hold special functions in the dining room, provided that the date
of holding the special function is coordinated with the Tenant in building 30 [sic].

	

	If
a preferred date for the holding of a function by one of the tenants in building 30 overlaps with a preferred date for the holding of a function by a
third party, preference shall be given to the tenant in building 30. 

3

 

	

	For
the avoidance of doubt and without derogating from the Tenant's liability as provided in the agreement and this addendum, it is hereby expressed that
the Tenant shall be liable for any damage to person and/or property occasioned to the Tenant's employees and/or to any third party which is directly or indirectly connected with a special function
held by the Tenant and/or anyone on its behalf in the dining room.

	

	If
a claim is filed against Matam by any of the Tenant's employees or by any third party in respect of damage for which the Tenant is liable pursuant to
this sub-clause, the Tenant shall indemnify Matam, subject to the Tenant being given notice regarding the existence of the proceedings against the Company and to it being given the opportunity to
defend itself against the claims raised within the framework of the aforementioned proceedings, in respect of any amount which Matam is made liable to pay any of the Tenant's employees and/or any
third party, together with trial costs and including principal, interest, linkage, official fees, advocates' professional fees, VAT and any other expenses deriving from the claim.

	3.6
	Without
derogating from the provisions of clauses 3.1 to 3.3 above and for the avoidance of doubt, it is hereby expressed that on the ground floor and fourth floor of the building
there are expenses relating to the maintenance of the common area which shall only be borne by the companies renting areas on such floors pursuant to their proportional part of the area let by the
Company on such floors in relation to the entire floor area.

 

	4.
	Liability With Regard to The Common Areas

	4.1
	The
Tenant hereby warrants that it is aware and agrees that:

	4.1.1
	The
catering services in the dining room, including the payment in respect thereof, are regulated in the agreement between the contractor and the Tenant which is annexed hereto as
appendix "B".

	

	Matam
shall not be howsoever liable for the catering services and, inter alia and without derogating from the generality of the aforegoing, for the quality
of the food and/or any damage to person and/or property occasioned to the Tenant and/or any third party which is directly and/or indirectly connected with the catering services.

	4.1.2
	Without
derogating from the provisions of clause 11 of the agreement, the Tenant alone shall be liable vis-a-vis Matam and/or any third party, as the case may be, for any injury,
loss or damage to person or property (and without derogating from the generality of the aforegoing, including property of the Tenant, its employees and guests) which occurs or is occasioned in the
domain of the common areas in consequence of an act and/or omission of the Tenant and/or anyone acting on its behalf and/or Matam and/or anyone acting on its behalf and the aforementioned liability
shall not be borne by Matam, subject to the provisions set forth below.

	

	The
Tenant's liability as provided above in this sub-clause, insofar as it relates to an act or omission of Matam and/or those acting on its behalf, shall
be in accordance with that defined under the third party liability insurance policy as provided in clause 12(a)(3) of the agreement, with it being limited to an amount of US$ 5,000,000 per
event and in total for the entire insurance term.

	4.1.3
	If
a claim is filed against Matam by any third party in respect of damage for which the Tenant is liable pursuant to this clause 4, the Tenant shall be liable to indemnify Matam,
immediately upon being requested to do so, in respect of any amount which Matam shall be held liable to pay the third party, together with all Matam's expenses in respect of conducting the trial with
the third party and, without prejudice to the generality of the 

4

 

aforegoing,
principal, interest, linkage, advocates' professional fees, official fees, trial costs, VAT and any other expenses deriving from the claim. 

	

	Matam's
indemnity by the Tenant shall be conditional upon the Tenant being given notice regarding the existence of the proceedings against Matam and upon
the Tenant being given an opportunity to defend itself against the claims raised within the framework of the aforementioned proceedings.

	4.1.4
	The
Tenant undertakes to indemnify and/or compensate Matam immediately upon being requested to do so in respect of any damage and/or expense occasioned to Matam in consequence and
in respect of a breach of the Tenant's obligations pursuant to this addendum.

	4.1.5
	It
is not the intention of this clause, and all the sub-clauses hereof, to create rights in favour of any third party.

	4.1.6
	The
sub-clauses of this clause supplement and do not derogate from each other.

	4.1.7
	For
the purpose of clause 3.5 and this clause 4, the expressions "damage" and "Matam" shall bear the meaning prescribed in clause 12 of the agreement.

 

	5.
	Payment in Respect of the Management and Maintenance of the Common Areas

	5.1
	Subject
to the transfer of data on the planned budget as provided in clause 5.4 below, the Tenant undertakes to pay the Company, at the time of paying the rent as prescribed in the
agreement, the proportional part of the routine expenses, as defined in clause 2 above, overheads and management fees and dining room expenses, as provided in this addendum and the appendices hereto.

	5.2
	The
amount of the routine expenses and overheads and management fees that shall be paid to the Company by the Tenant, as prescribed in this addendum and the appendices hereto, shall
be detailed in a written request that the Company shall give the Tenant from time to time, and they shall be paid by the Tenant to the Company upon effecting the next rent payment following the
receipt of any request.

	

	It
is hereby agreed between the parties that the Tenant may request from the Company, and the Company hereby undertakes to furnish to the Tenant following
receipt of such a request, invoices or other documents approved by the Company's comptroller (including agreements) attesting to the amount of the routine expenses incurred by the Company within the
framework of maintaining the common areas.

	5.3
	For
the avoidance of doubt, it is expressed and agreed by the parties that the payment of monies by the Tenant to the Company for the maintenance and management of the common areas as
prescribed in sub-clause 5.1 and 5.2 above shall be effected commencing from the delivery of the premises to the Tenant as provided in the agreement and until the end of the tenancy term.

	5.4
	It
is hereby agreed that one month before the commencement of each calendar year during the tenancy term the Company shall convey to the Tenant, for its inspection, data on the
planned budget for the management and maintenance of the common areas (hereinafter referred to as "the planned budget") for the coming calendar year. A deviation of more than 5% from the planned
budget shall necessitate the Tenant's prior written consent (in respect of a deviation of more than 5%).

	

	For
the avoidance of doubt, a deviation of up to 5% does not require the Tenant's consent. 

5

 

	6.
	General

	6.1
	The
Tenant hereby warrants that it is aware that pursuant to the agreement that shall be executed/has been executed between the Company and the contractor for the provision of
catering services, the Company is reserving unto itself, inter alia, the right to bring about early termination of the term for borrowing the dining room that shall be given/has been given to the
contractor, and such being by giving 30 days' prior written notice to the contractor and without being required to give grounds for its said decision.

	

	The
Tenant warrants and undertakes that it does not and shall not have any complaints and/or claims and/or demands against the Company in connection
therewith, provided that the Company contracts with another contractor for the provision of catering services and that the provision of the catering services to the tenants in building 30 is not
affected.

	6.2
	It
is hereby agreed that save for the provisions of this addendum and the appendices hereto, there shall be no alteration to the terms and conditions of the agreement and the
appendices thereto. 

 
 

AS WITNESS THE HANDS OF THE PARTIES:    
    

	
 The Tenant	 	
 The Company

6

 
 
 

SPECIAL TERMS AND CONDITIONS APPENDIX    
    

	1.
	The
Company warrants that it intends erecting in the area of the Science Industries Park in Haifa, including the area known as Matam West (hereinafter referred to as "the Centre") a
building of a total area of approx. 5,000 square metres (hereinafter referred to as "the planned building") which shall be built on the basis of a specification that shall be agreed between the
parties and which shall not be inferior to the specification of building 30 and building 23 which were built by the Company in the Centre.

	

	The
location of the planned building shall be determined by Matam within Matam West Park, by consent with Zoran—and Zoran shall not object to
the location on unreasonable grounds.

	2.
	The
Tenant warrants that it wishes to rent an area of approx. 2,500 square metres in the planned building for a term of seven years, commencing at the end of the tenancy term in
respect of the premises in building 30, i.e. commencing from 15th May 1999.

	3.
	It
is hereby agreed that the location and size of the planned building shall be determined by the Company in its discretion, having regard to the Tenant's requirements.

	4.
	It
is further agreed between the parties that:

	4.1
	The
Tenant shall notify the Company in writing by 15th May 1997 if it wishes to increase or reduce the area which it shall rent in the planned building by 500 metres.

	4.2
	The
Tenant may sub-let an area of up to 40% and not more than 1,000 square metres of the area which it shall rent in the planned building for a period of up
to                                         
                 ;
however, it is hereby expressed that a sub-tenancy as aforesaid shall be conditional upon obtaining the Company's prior written approval and to fulfillment of the terms and conditions set forth below:

	4.2.1
	The
Tenant shall give a written prior undertaking to the Company's satisfaction that it shall remain liable for the performance of all its obligations to the Company, including
pursuant to the tenancy agreement and the appendices thereto, that it shall be liable for all the acts and/or omissions of the sub-tenant, and that the sub-letting of the premises and/or any part
thereof by it shall not howsoever derogate, directly or indirectly, expressly or impliedly, from the Tenant's obligations to the Company pursuant to the tenancy agreement and the appendices thereto.

	4.2.2
	The
Tenant shall give the Company written approval from its parent company                             that
it agrees to the Tenant sub-letting the premises and/or any part thereof and that it
is aware and agrees that the guarantee which it has given for the performance of the Tenant's obligations pursuant to the tenancy agreement shall remain in force unaltered and that the sub-letting
shall not howsoever derogate from its obligations and/or the Tenant's obligations vis-a-vis the Company as provided in the tenancy agreement and the appendices thereto.

	

	For
the avoidance of doubt, it is hereby expressed that the collaterals that the Tenant shall give the Company, including the guarantee of the parent
company, shall serve to secure the obligations of the Tenant and the sub-tenant.

	4.2.3
	The
sub-tenant may not transfer and/or assign and/or charge its rights in the premises to any other entity.

	4.2.4
	The
object of the sub-tenant and the nature of its activity accord, in the Company's exclusive discretion, with the normal activity in the Centre. 

7

 

	4.3
	The
remaining areas in the planned building that are not let to the Tenant shall be let to other entities in the Company's exclusive discretion. Letting to other entities as aforesaid
shall be for a term of up to three years, and such being in order to enable Zoran's future expansion by the letting of additional areas in the planned building.

	

	Notwithstanding
the above provisions in this sub-clause, it is hereby expressed that a decision regarding the entities to which the areas in the planned
building should be let and for what period of time is within the Company's exclusive discretion.

	4.4
	It
is agreed between the parties that the rent which the Tenant shall pay the Company for the rental of an area in the planned building or for the alternative premises (as defined in
clause 6 below) shall be as provided below:

	4.4.1
	The
monthly rent for each 1 square metre of the area of the premises in the planned building or in the alternative premises, as the case may be, shall be $12.74 (twelve US dollars
and seventy four cents) together with due VAT and linkage to the index (with the base index being the index for February 1996), as follows:

	4.4.1.1
	the
rent for 1,330 square metres shall be linked, from the commencement of the tenancy term and until 15th May 2003, to the rate of the dollar together with CPI linkage;

	4.4.1.2
	in
respect of the entire area rented that is in excess of 1,330 square metres, the rent shall be linked to the Consumer Price Index in Israel, with the base rate of exchange being
NIS 3.11 per US$1;

	4.4.1.3
	the
rent for 1,330 square metres of the area of the premises, as provided in sub-clause 4.4.1 above, shall, commencing from 16th May 2003, be identical to the average of the rent
for the area of the premises in excess of 1,330 square metres in accordance with the provisions of sub-clause (2) and the rent in NIS in May 2003 computed pursuant to clause (1).

 

	5.
	The Tenant hereby warrants that it is aware and agrees that the Company is not undertaking to erect the planned building and that it
does not and shall not have any complaints and/or claims against the Company in such regard.

	

	The
Tenant further warrants that it is aware that the decision on the planned building's erection is conditional, inter alia, on obtaining the approval of
the Company's board of directors and on obtaining approvals from the various competent authorities.

	6.
	The parties hereby agree that if the planned building is not erected for whatsoever reason, the Company shall let to the Tenant, and the
Tenant shall rent from the Company, alternative premises of an area of approx. 1,330 square metres the specification whereof shall be of a standard similar to that existing in the premises in building
30 mutatis mutandis (hereinafter referred to as "the alternative premises").

	

	The
alternative premises shall be let to the Tenant for a period commencing from 16th May 1999 and ending on 15th May 2003.

	7.
	It is hereby agreed that all the other terms and conditions of the tenancy agreement that shall be executed between the parties
regarding the area in the planned building or the alternative premises, as the case may be, shall be in accordance with the terms and conditions of the agreement executed between the parties regarding
the rental of an area in the building known as building 30 in the Centre, mutatis mutandis. 

8

 
 
 

AS WITNESS THE HANDS OF THE PARTIES:    
    

	
 The Company	 	
 The Tenant

9

 
 

ADDENDUM TO UNPROTECTED TENANCY AGREEMENT    
    

Entered into and Signed on the 31st Day of the month of October in the Year 2004  

Between: 

MATAM, Haifa Industrial Data Center Ltd.

Private Company No. 51-068740-3

("the Company") 

on
the one hand 

and: 

ZORAN Microelectronics Ltd.

Private Company No. 51-094944-9

("the Tenant") 

on
the other hand 

	Whereas	 	and in conformance with the Unprotected Tenancy Agreement dated 16.9.1998 (complete with all Annexes and Addenda thereto), the Tenant is renting from the Company areas in the ground, 2nd, 4th and 5thfloors in the edifice known as Building 30 in the Haifa Industrial Data Center ("the Original
Agreement" and "the Premises"), as specified under the Original Agreement;
	

and whereas	
 	
Tenant wishes to hire from the Company the 3rd floor in the building ("the Floor")
with a gross area of 1,342 m2, in order to increase the rented Premises, all with the consideration and conditions specified hereinafter under the present Addendum;
	

and whereas	
 	

the Company agrees to increase the Premises by adding the Floor, all with the consideration and conditions
specified hereinafter under the present Addendum;
	

and whereas	
 	

the Tenant and the Company wish to enter into a new Tenancy Agreement, in the context of which the Company
shall build a new building at the Haifa Industrial Data Center (hereinafter: "the New Premises") and rent it out to the Tenant, thus instead of the
Premises—all as the Parties shall agree upon in the context of the new contractual agreement;

THE PARTIES HAVE THEREFORE STIPULATED, DECLARED AND AGREED AS FOLLOWS:  

	1.
	Preamble and Annexes:  

The
preamble and annexes to this Addendum constitute an integral part thereof. 

	2.
	Premises Increased Area:

	2.1
	It
is hereby declared that the holding of a 671 m2 area within the floor area was delivered to the  Tenant on 1.11.2004, whereas holding of an
additional 671 m2 area within the floor was
delivered to the Tenant on 28.11.2004;

	2.2
	It
is also declared that the Floor was delivered to the Tenant as free of any man and
object and "as is", in the state it was received from the occupants who held it prior to delivery to the Tenant, and the  Tenant has, nor will they have,
any claim and/ or complaint and/ or demand from the Company in respect
thereof, except claims concerning hidden flaws and/ or defects which could not be detected in the course of a reasonable inspection and/ or inspection performed by the  Tenant;

	2.3
	Upon
delivering holding of the Floor and/ or any part thereof to the Tenant, the  Floor and/ or any part thereof
was added to the Premises area, and all  Tenant's obligations under the provisions of the Original Agreement
shall apply, with the obvious
changes relating to the Premises area in the added Floor or part thereof (together, the  Premises and the
Floor shall hereinafter be referred to as: "the Increased
Premises"), including, and without prejudice to the generalities stated regarding 

 

the  Tenant's liability, increased rental and sureties as specified hereinafter, increased payments for taxes, charges, increased Insurance coverage, and
such. 

	3.
	Adjustment works:

	3.1
	It
is explicitly agreed that all the works to adjust the Floor (design and performance) shall by performed by the  Tenant and at their cost and under their
liability (negating the Company's liability). 

All
the adjustment works shall be performed by the Tenant, only after and subject to receiving the  Company's agreement for such works, in writing and in
advance. The Company shall not withhold its
agreement to the Tenant's works unless for reasonable causes of damage to the construction and/ or external wraparound and/ or the electronic system
and/ or building security. The Company shall approve the Tenant's designs within 14 days from
their being submitted. To avoid any and all doubt, receipt of the Company's approval of the adjusting works shall not impose any liability whatsoever on
the Company concerning these works and/ or prejudice the Tenant's responsibility for the adjustment
works; 

	3.2
	Under
the Law, the Tenant's is responsible for any bodily injury and/ or damage to property of any kind and type whatsoever that may be
caused to any person and/ or the Premises and/ or the Floor and/ or the contents thereof resulting and/
or relating to the adjustment works inasmuch as they are caused and/ or have occurred following an act of negligence and/ or failure on the part of the  Tenant and/ or whomever on their behalf.

Tenant is under the obligation to avoid as much as possible causing nuisances that could prevent the other building occupants from reasonable using
their own premises. 

Tenant is under the obligation to insure the adjustment works performance, in conformation with the Insurance Annex attached as Annex J to the  Tenancy Agreement in relation to the new building; 

	3.3
	Tenant is under the obligation to arrange, at its own expense, for obtaining the licenses required and/ or that shall be required by
Law, inasmuch as those exist, for performing the adjustment works on their own and/ or by whomever on their behalf in the building;

	3.4
	It
is hereby agreed that any completion or addition to be performed in the Increased Premises, as stated hereinabove at the  Tenant's expense, shall become the
Company's property, beginning on the vacation date from the  Increase Premises, thus in the event that the addition or alteration comply with the definition
"connected" as defined under the 1969 Law of Properties,
with the exception of end equipment which is the Company's property;

	3.5
	The  Company is under the obligation to participate in the adjustment works performance cost, up to amount equal in NIS. to US$ 60 per
m2 of the Floor area ("Participation Fees"). The said  Participation Fees shall be paid to the
Tenant for performing additions to interior finish and
completion works, including sprinklers, partitions, acoustic ceilings doors, carpets, lighting, electric infrastructure, communication infrastructure (conduits and inspection pipes), flooring,
painting, air conditioning, design, management and supervision costs, and such. To avoid any and all doubt, the Participation Fees shall not be paid for
furniture, communications (except for infrastructure) and all Tenant's other specific equipment. 

The
Company shall pay the Participation Fees to the  Tenant against approved contractors' invoices. Payment shall
be effected under current + 30 terms; 

	3.6
	The  Company is under the obligation to perform under its responsibility and at its cost, renovation works on the building, in
conformance with the specifications under Annex A to the present Addendum. 

2

 
	4.
	Tenancy:

	4.1
	The  Tenancy in the Premises shall be extended and it shall last until the end of 10
(ten) days from the actual delivery date of the building that shall be erected at the MATAM Industrial Park by the Company for the  Tenant, as defined under
the provisions of the Tenancy Agreement relating the new building and shall be
signed by the Parties. 

Delay
of up to 10 (ten) days in vacating the Increase Premises by the Tenant shall not be considered as
a breach of the Original Agreement and/ or the present Addendum; 

	4.2
	Tenancy of the Floor shall commence on the date of delivery the holding of any part
thereof to the Tenant, as specified under sub- clause 2.1 hereinabove, and shall also last until the  Tenancy completion date in the Premises, as specified under sub- Clause 4.1
hereinabove.

	5.
	Parking:

In
the context of adding a Floor as stated hereinabove, the Company shall allocate to the  Tenant and for the
entire Tenancy' 9 (nine) assigned parking places in addition to the assigned parking
places that were allocated to the Tenant under the provisions of the Original Agreement, at the same
terms defined under the Original Agreement. It is clarified that the overall number of assigned parking places shall stand on...... parking places. 

	6.
	Rent:

	6.1
	On
account of the Floor and/ or any part thereof, the Tenant shall pay to the  Company, beginning on the holding
delivery date as specified under the provisions of sub- Clause 2.1 hereinabove and throughout the  Tenancy and on account thereof, a monthly rent equal in NIS. To US$ 10.40 for every 1 m2,
 with the addition of VAT according to the Law;

	6.2
	Beginning
on 1.6.2005 and until the Tenancy termination date, the Tenant shall pay to
the Company, on account of the entire Increased Premises, a monthly rent equal in NIS. To US$ 10.40 for
every 1 m2 of the Increased Premises area, with the addition of VAT according to the Law. For avoidance of any doubt, it is clarified that
the rent according to sub- Clause 6.1 hereinabove do not come in addition to the rent defined under this sub- Clause, rather they are absorbed within and constitute a
part thereof;

	6.3
	The
said rent mentioned hereinabove shall be converted to NIS (New Israeli Shekel) at the time of signature on thee present Addendum, and they shall bear linkage differentiation to
the Consumer Price Index, in conformance with the ratio between the Index known on the said signature date and the last Index known at the date of actual execution of each and every payment;

	6.4
	Subject
to the alterations mentioned hereinabove, all the provisions under the Original Agreement shall apply to the monthly rent,
including with regard to payment date and execution mode.

	7.
	Guarantees:

To
ensure the implementation of every one of the Tenant obligations under the Original Agreement,
including the present Addendum, the Tenant shall—upon signature of this Addendum—increase the sureties that were given by them
to the Company on account of the Original Agreement, in a relative manner to the increase of premises. 

	8.
	General:

	8.1
	Whenever
in this Addendum any amount in US Dollars was stated, it was meant for convenience only. Upon signature of this Addendum, the amounts mentioned in US Dollars shall be
converted into NIS (New Israeli Shekels) according to the Dollar currency rate at the time of signature, meaning NIS. 4.468 for every US$ 1; 

3

 
	8.2
	It
is explicitly agreed that every provision under the Original Agreement, inasmuch and as much as they were modified under the present
Addendum, shall remain valid, without changes and shall obligate both Parties with all its implications;

	8.3
	In
the event of any contraction among the Original Agreement provisions and those under this Addendum, the latter shall prevail. 

IN WITNESS THEREOF, THE PARTIES HAVE SIGNED AS FOLLOWS:  

	 	 	 
	
The Company	 	
 The Tenant

4

REF: F:/ZORAN/TENANCY APP./SM/29/11/99

[TRANSLATED FROM THE HEBREW] 

 
 

APPENDIX ADDENDUM
  TO UNPROTECTED TENANCY AGREEMENT OF 16.9.97    
    

Made
and signed on the                             day
of                                         
                 1999 

	

Between:	
 	
Matam—Haifa Information Industries Centre Ltd

PC 51-068740-3

(hereinafter referred to as "the Company")
	

 	
 	
of the one part
	

And:	
 	
Zoran Microelectronics Ltd

PC 51-094944-9

(hereinafter referred to as "the Tenant")
	

 	
 	
of the other part
	

Whereas	
 	

in accordance with the unprotected tenancy agreement executed on 16th September 1997 (together with the appendices thereto), the Tenant is renting from the Company an area on the fifth floor and an area on the ground floor in a building known as
building 30 (hereinafter referred to as "the building") in the Haifa Information Industries Centre (hereinafter referred to as "the agreement" and "the premises" respectively), all as provided in the agreement and the appendices thereto;
	

And Whereas	
 	

the building contains an area which is located on the sixth floor as outlined in green on the drawing annexed hereto as appendix "A" and constituting an integral part hereof, including equipment which was installed therein by the Company (hereinafter
referred to as "the additional area");
	

And Whereas	
 	

the Tenant wishes to rent the additional area from the Company in order that it be added to the area of the premises and to extend the tenancy term, for the consideration and on the terms and conditions set forth below;
	

And Whereas	
 	

the Company agrees to the increase of the premises by the addition of the additional area and to the extension of the tenancy term, for the consideration and on the terms and conditions set forth below;

Accordingly, it is provided, warranted and agreed between the parties as follows:  

	1.
	 Recitals and Appendices

	

	The
recitals and appendices hereto constitute an integral part hereof.

	2.
	Increase of The Premises

	2.1
	The
additional area shall be added from 1st February 2000, subject to the Company's obligation as provided in clause 3.1 below, to the area of the premises and all the parties'
obligations pursuant to the agreement (as defined above), save for clause 5(a) (with regard to the tenancy term) shall apply mutatis mutandis to the area of the premises with the addition of
the additional area (the premises and the additional area shall hereinafter jointly be referred to as the "increased premises"), including, and without derogating from the generality of the
aforegoing, with regard to the Tenant's liability, increase in the contribution towards the dining room expenses and management and maintenance of the common areas, increase in the payments of taxes
and levies, increase in the insurance cover and the like. 

	

	Without
derogating from the aforegoing, and for the avoidance of doubt, it is hereby expressed that in consequence of the addition of the additional area to
the area of the premises, the number of designated parking bays that shall be placed at its disposal shall be increased relative to the increase in the area of the premises, that is to say, the Tenant
shall be entitled to receive from the Company, during the tenancy term, a right to use a further nine designated parking bays on the same terms and conditions as laid down in the agreement.

	

	It
is agreed that the tenancy term in respect of the increased premises shall come to an end on 31st May 2005 and not as provided in clause
5(a) of the agreement.

	2.3
	For
the avoidance of doubt, it is hereby expressed that the area of the "additional area" (as defined above) for the purpose of computing the amount of the rent and the other payments
for which the Tenant is liable pursuant to the agreement and this addendum, is the gross area of the "additional area", that is to say, 1,342 square metres, including the Tenant's proportional part of
the common areas.

	

	The
monthly rent which the Tenant shall pay in respect of the rental of the additional area shall be in a sum of US$12.74 for every square metre of the
additional area for the purpose of payment of the rent together with due VAT and linkage as provided in clause 7(c)(1) of the agreement. The monthly rent in respect of the additional area shall
be paid by the Tenant at the times and in the manner mentioned in clause 7 of the agreement.

 

	3.
	Organisation and Execution of The Tenant's Works

	3.1
	The
Company is granting the Tenant and Tenant is receiving from the Company a right to use the additional area two months prior to the date of delivering possession of the additional
area, that is to say, for a period from 1st December 1999 until 1st February 2000 (hereinafter referred to as "the organisation period"). In the organisation period the Tenant's status
in the additional area shall be that of borrower pursuant to the Hire and Loan Law, 5731-1971; however, subject to the Tenant's performance of all its obligations pursuant to the agreement and this
addendum, the Company may not cancel its obligation to grant the organisation period.

	

	The
Tenant acknowledges that the user right granted to it in the organisation period is limited solely to the execution of the Tenant's works in the
additional area for the purpose of adapting it to its requirements and that in the organisation period it may not make any other use of the additional area.

	

	In
the organisation period all the provisions of the agreement, save for the obligation to pay rent, shall apply to the Tenant in relation to the additional
area, mutatis mutandis.

	3.2
	It
is hereby agreed that in the organisation period the Tenant shall execute, at its expense and liability, the Tenant's works specified in appendix "C" hereto in accordance with
detailed plans that shall be prepared by the Tenant pursuant to the aforementioned appendix and which shall be submitted for the Company's prior written approval.

	

	The
Company shall approve and/or respond to the aforementioned detailed plans within seven days of receiving them. The Company warrants that it shall not
object to the plans on unreasonable grounds.

	

	Once
the Company has approved the detailed plans, the Tenant may commence executing the Tenant's works.

	

	The
Company shall participate in financing the cost of executing the Tenant's works specified in appendix "C" pursuant to the plans approved by it as
provided above (hereinafter referred to as "the finishing works"), which shall be executed by the Tenant, in an amount not exceeding a sum in NIS equal to US$200 (two hundred US dollars) for every
square metre of the additional area gross (as specified above in sub-clause 2.3), in accordance with the 

representative
rate of the US dollar last known on the date of the parties' execution hereof together with VAT and linkage to the building inputs index from the index last known on the date of the
parties' execution hereof until the index last known on the date of effecting any payment of the contribution. 

	

	The
contribution towards financing the cost of executing the Tenant's works shall be paid to the Tenant on the terms and conditions and at the times
specified below in sub-clause 3.3.

	3.3
	The
Company shall pay the aforementioned contribution in instalments (to the Tenant and/or to a third party on its behalf pursuant to its written instruction) in accordance with the
actual progress of the Tenant's works, within 30 days of receiving any invoice (interim and/or final) approved by the Tenant attesting to the expenses incurred by the Tenant in the execution of the
Tenant's works.

	

	No
later than the end of 90 days from the end of the execution of the Tenant's works, the Tenant undertakes to send the Company a report certified by an
auditor confirming that the expenses in respect of which the Company will be requested to pay a contribution to the Tenant were indeed incurred by it in the actual execution of the Tenant's works.

	3.4
	During
the organisation period, the Tenant shall execute the Tenant's works using experienced and qualified tradesmen and professionals after receiving, in addition to the aforegoing,
all the approvals required therefor, to the extent necessary, from the competent authorities and after furnishing an engineer's certificate that the Tenant's works are not such as to cause
irreversible damage to the additional area.

	3.5
	In
order to clarify matters, it is agreed and warranted by the parties that the Company's approval as mentioned above and below in this clause is not such as to impose on the Company,
directly and/or indirectly, expressly or impliedly, any liability in relation to the quality of the Tenant's works and/or their compliance with the conditions of the permit, the Israeli standard
and/or the manner of their execution and full liability in respect thereof shall be borne by the Tenant and the Tenant hereby waives any plea and/or claim vis-a-vis the Company in such regard.

	3.6
	The
Tenant shall act to the best of its ability to minimise disturbances and/or nuisances to the occupants of the building as a result of the Tenant's works.

	3.7
	The
Tenant may not store or leave materials and/or equipment and/or waste outside the additional area without the Company's prior written approval.

	3.8
	The
Tenant may not execute other works in the additional area that are not the Tenant's works pursuant to the specifications (appendix "C"), save with the Company's prior written
approval. The Company shall not refuse the Tenant's request to execute other works as aforesaid on unreasonable grounds.

	3.9
	The
Tenant shall be liable for any damage or loss occasioned, if at all, directly or indirectly, in the course and/or in consequence of the execution of the Tenant's works to any
person and/or property and/or the additional area and/or the Centre and/or their surroundings and/or contents. Without prejudice to the generality of the aforegoing, in such regard the approval of the
specifications by the Company shall not impose any obligation or liability on it, [and] shall not constitute a waiver of any right of the Company, and the Tenant hereby exempts
the Company from any liability in connection with approval of the specifications (appendix "C") and/or deriving from such approval.

	3.10
	The
Tenant undertakes to repair any damage and/or loss occasioned in consequence of the execution of the Tenant's works to the additional area and/or the building and/or the Centre
or their contents or to works executed on other premises or the common areas within a reasonable time in accordance with the type of the damage. If the Tenant does not act as aforesaid—the
Company may, after giving the Tenant written notice, immediately effect the necessary repairs instead of the Tenant and at its expense, and the Tenant shall indemnify the 

Company
immediately upon demand in respect of any expense borne by the Company in effecting the repair as aforesaid, together with handling fees at a rate of 20% (twenty percent). 

	3.11
	Without
derogating from the Tenant's liability as provided in clauses 3.9 and 3.10 above, the Tenant undertakes to insure the Tenant's works, at its expense, from the date of the
organisation period's commencement until completion of the execution of the Tenant's works in the additional area or until the date of delivering possession of the additional area, whichever is the
later. The Tenant undertakes to comply with all the insurance company's requirements, if any, in respect of the execution of the Tenant's works, including—but without derogating from the
generality of the aforegoing—with regard to safety measures and facilities, the composition of materials and the like.

	

	The
provisions of clause 12 of the agreement shall apply to the manner of issuing the aforementioned policy and the format thereof, mutatis mutandis.

	3.12
	It
is expressly agreed that, subject to the performance of the Company's obligation as provided in sub-clause 3.1, the execution of the Tenant's work shall not be such as to postpone
the date of delivering the additional area and that even if the Tenant does not complete the execution of the Tenant's works, for any reason, the Tenant shall be bound, from the date of delivering the
additional area and throughout the tenancy term, by all its obligations in relation to the increased premises pursuant to the agreement and this addendum, including the obligation to pay rent.

	3.13
	In
the event that the Tenant does not perform, in the organisation period, any of its obligations and/or does not make any of the payments which it owes pursuant to the terms and
conditions of the agreement and this addendum in the organisation period, all or any of them, such shall constitute a fundamental breach of the agreement and this addendum and the Company may, subject
to giving the Tenant written notice of the breach, and the breach is not rectified by the Tenant within 14 days of the notice's receipt, act in its exclusive discretion as follows:

	3.13.1
	Postpone
the commencement of the tenancy Term in respect of the additional area until the performance of the Tenant's obligations and the making of all the payments which it owes;
however, the Tenant shall be liable to perform all its obligations pursuant to the agreement and the addendum in full as though the additional area had been delivered to it on the date of commencement
of the tenancy term in respect of the additional area specified in this addendum, all without derogating from any other relief to which the Company shall be entitled pursuant to the agreement and the
addendum and/or at law.

	3.13.2
	Notify
the Tenant of the addendum's termination, of the completion of the organisation period and evict it from the additional area immediately, without the need for any warning.

	

	It
is agreed and warranted by the parties that if, notwithstanding the Company's eviction notice, the Tenant and/or anyone on its behalf remains in the
additional area, such shall be by way of trespass, and it shall be estopped from doing any act against the Company and/or from making any plea against it, if the Company takes any steps in order to
remove the Tenant from the additional area and regain full possession thereof.

	

	The
Tenant shall not be entitled to any compensation and/or restitution in respect of expenses borne by it in the execution of the Tenant's works and/or any
amount paid by it in the organisation period.

	3.14
	The
provisions of this clause 3 with regard to the Tenant's obligations are in addition to and do not derogate from the Tenant's obligations pursuant to the agreement and the
addendum and they shall not derogate from any other and/or further right and/or relief vested in the Company pursuant to the agreement and/or the addendum and/or at law. 

	4.
	Early Vacation of The Building's Ground Floor

	4.1
	It
is hereby agreed that in consequence of the delivery of the additional area to the Tenant, as provided above in clause 2, the Tenant may, during the tenancy term, vacate the ground
floor area of a size of 304 square metres, which constitutes part of the increased premises (hereinafter referred to as "the ground floor area"), subject to the fulfilment of all the following
cumulative conditions:

	4.1.1
	The
Tenant shall give the Company at least 30 days' written notice of its intention to vacate the ground floor area.

	4.1.2
	In
consideration for the Company's consent to curtail the tenancy term in respect of the ground floor, insofar as it relates to the ground floor alone, and as a condition therefor,
the Tenant shall pay the Company a sum in NIS equivalent to four months' rent for the ground floor area for the purpose of paying rent (that is to say, the gross ground floor area, including the
Tenant's proportional part, in connection with this area, of the common areas) together with due VAT. The aforementioned amount shall be paid to the Company by the Tenant from the date of the Tenant's
notice as provided above in sub-clause 4.1.1 in four instalments at the times prescribed in the agreement (including this addendum) for payment of the rent in respect of the increased premises and the
linkage conditions laid down in the agreement, including this addendum, shall apply in respect of the aforementioned payments.

	

	If
the area of the premises is reduced as aforesaid, the provisions of clause 2 shall be amended accordingly.

 

	5.
	Collateral

	5.1
	To
secure the performance of all the Tenant's obligations pursuant to the agreement, including this addendum, the Tenant is depositing with the Company (in addition to the collateral
which it gave the Company pursuant to the agreement, which shall continue to remain in force until the end of the tenancy term in respect of the increased premises), at the time of the execution
hereof and as a condition therefor, the following collateral:

	5.1.1
	A
blank promissory note in a sum of US$40,000 (forty thousand US dollars) to the order of the Company, payable upon demand, signed by the Tenant (hereinafter referred to as "the
note"), and all the provisions of clause 10(a) of the agreement shall apply in respect of the aforementioned note.

	5.1.2
	In
addition, the Tenant shall give the Company written confirmation, to the Company's satisfaction, from the parent company Zoran Corporation confirming that it is familiar with the
provisions of this agreement and that it agrees thereto and that the guarantee given by it in accordance with the provisions of clause 10(b) of the agreement shall apply to all the Tenant's
obligations pursuant to the agreement, including this addendum, and that this addendum is not such as to howsoever derogate from the guarantee given by it.

 

	6.
	The Third Floor of The Building

	

	It
is agreed that if by 1st June 2000 Aurec vacates the third floor of the building, the Tenant shall have a right of first refusal to rent this area
from the Company (in addition to the increased premises) for the balance of the tenancy term, as follows:

	6.1
	The
Company shall approach the Tenant with an offer to rent the third floor of the building, stating the price, terms and conditions required which shall be identical to the terms and
conditions offered to a third party.

	

	If
the Tenant does not notify the Company in writing of its wish to exercise the said right of refusal on the terms and conditions specified in the offer,
within 10 days of the Company's approach, the Company shall be entitled to offer the third floor of the building to any third party, at a price and on terms and conditions not better than those stated
in the offer to the 

Tenant,
and the Tenant does not and shall not have any pleas and/or claims and/or demands vis-a-vis the Company in such regard. 

	6.2
	For
the avoidance of doubt, it is hereby expressed that the Tenant's aforementioned right of refusal is for a limited term ending on 1st June 2000 and the Tenant hereby
warrants that it does not and shall not have any pleas and/or claims and/or demands vis-a-vis the Company in such regard.

 

	7.
	General

	

	It
is expressly agreed that all the provisions of the agreement insofar as and to the extent not altered by this addendum shall remain in force without
change and shall bind the parties for all intents and purposes. 

 
 

AS WITNESS THE HANDS OF THE PARTIES:    
    

	(Signed and Stamped)
 The Company	 	(Signed and Stamped)
 The Tenant

 
 

APPENDIX "C"—TECHNICAL SPECIFICATION    
    

	A.
	Division
into offices with single membrane plaster board [?] (width 10 cms with 2" rockwool insulation) of a height of up to 3 metres in a quantity of 440
metres in length.

	B.
	Doors,
wooden 50% with top coat colour at the architect's election, 30 units.

	C.
	Carpet.
Basic price per carpet: $15/sq.m. including panel and laying down the carpet.

	D.
	Demolition
and removal works.

	E.
	Electricity
and telephone: 

        60
power points + with a group of three outlets at each point. 

        60
telephone points. 

        60
computer points (preparation only). 

	F.
	Sprinklers:
adaptation of sprinkler location.

	G.
	Air
conditioning: adaptation of location of Nachshon blower units.

	H.
	Fiber
acoustic ceiling with 60/60 measurements including [?] recessed units on the entire floor. 

QuickLinks

Exhibit 10.36

AGREEMENT

AS WITNESS THE HANDS OF THE PARTIES

APPENDIX "I" ADDENDUM TO THE TENANCY AGREEMENT DATED

AS WITNESS THE HANDS OF THE PARTIES

SPECIAL TERMS AND CONDITIONS APPENDIX

AS WITNESS THE HANDS OF THE PARTIES

ADDENDUM TO UNPROTECTED TENANCY AGREEMENT

APPENDIX ADDENDUM TO UNPROTECTED TENANCY AGREEMENT OF 16.9.97

AS WITNESS THE HANDS OF THE PARTIES

APPENDIX "C"—TECHNICAL SPECIFICATION

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00088-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00088-of-00352.parquet"}]]