Document:

Exhibit 10.6

    

      Exhibit
        10.6

      

      Construction
        Agreement

      

      

      Party
        A:
        Shannxi Kai Da Lv You Gu Wen You Xian Gong Si 

      Address:
        Hongguan Road, Xi’an City.

      Postcode:710086

      Telephone:029-84368561

       

      Party
        B:
        Wu, Lianshe

      Address:
        Qindu District, Xianyang City, Shaanxi Province

      Postcode:
        712000

      ID
        Card
        No.:610402560325181

      

      After
        the
        consultation, Party B takes the design task of 4A level reconstruction project
        of the Theme Park of E Pang Gong Palace, and the two parties come into the
        agreement as following:

      1.    
        The
        reconstruction place, area and the design contents:

      1.1  
        The
        reconstruction project place: the Theme Park and hotel

      1.2   The
        reconstruction area: 540,000 m2.

      1.3  
        The
        design contents and standard: international 4A level.

      2.    
        The
        obligations of Party A:

      2.1   Providing
        Party B with the prospectus proved by the relevant superior governmental
        department before October 1. 2005.

      2.2  
        Providing
        Party B with he document of agreement about raw material (or resource report
        authorized), fuel, water, electricity, traffic and so on, the reconnaissance
        data that can satisfy the original planning requirement, the technique data
        through scientific research..

      2.3  
        Being
        responsible for the approval for every stage of the reconstruction.

      2.4  
        Being
        responsible for the fees of trip and bussiness caused by the outside experiment
        because of the technical need.

      2.5  
        Providing
        Party B the necessary room for living and dining (fees beared by Party
        B).

      2.6  
        Protecting
        the intellectual property of Party B and not delivering it to any third
        party.

      3.    
        The
        obligations of Party B:

      3.1   Selecting
        the experienced designing staff for the project who succeeded many
        designs.

      3.2  
        Providing
        Party A with the designing document within the scheduled time.

      3.2.1    
        Delivering
        the draft plan (4 versions) of the reconstruction project before October
        31,
        2005.

      3.2.2    
        Delivering
        the final plan (4 versions) of the reconstruction project before November
        20,
        2005.

      3.2.3    
        Delivering
        the working drawing (4 versions) together with the final plan of the
        reconstruction project before October 31, 2005. if Party A needs more copies
        of
        the drawing and the making mode, both parties can consulting for the additional
        fees.

      3.2.4    
        Delivering
        the budget document of the reconstruction project and the relevant material
        before November 25, 2005.

      3.3  
        Carrying
        out the project design strictly with the proved prospectus and the 4level
        standard, and getting consent when making any change.

      3.4  
        Revising
        the draft plan and the final plan again and again based on the suggestion
        of
        Party A and relevant department till getting the final approval by the
        authority.

      3.5  
        Bearing
        any additional fee related to the design but exceeds the pay by Party
        A.

      4.    
        Design
        revision, approval and termination:

      4.1  
        Once
        the
        project design is proved by the authority, it means that Party B has finished
        its task. If Party A require to amend the design of construction, it has
        to get
        the consent from the authority and get the relevant document, then consult
        with
        Party B of the revision contract and the design fee.

      4.2  
        The
        fee
        standard of the significant change to the design: increase the design fee
        RMB
        5,000 per working day (or pusuant to the percentage of the revising work
        volume
        in the design stage).

      4.3  
        Party
        A,
        if want to stop the design during the working period, shall inform the other
        party in time, and cannot get the paied fee back..

      5.    
        Design
        fee and pay date:

      5.1  
        Party
        A
        shall pay an aggregate of $US150,000 or 600,000 share which can be freely
        traded
        on American stock market.

      5.2  
        After
        signing the contract, Party A shall anticipate $US30,000 of the aggregate
        $
        US150,000; and pay the left amount within 10 working days after receiving
        the
        revised draft and the working drawing. If using share, Party A shall pay
        600,000
        share within 10 working days after receiving the revised draft and the working
        drawing, and Party B shall return the $US30,000 to Party A when receiving
        the
        600,000 share.

      6.   
        Encouragement and default provision

      6.1
        If he
        construction investment could be saved in rational controlled number because
        Party B adopts advanced technology and rational suggestion, Party B could
        deduct
        5% from the saved investment as bonus. 

      6.2  
        If Party B cannot work or redesign because Party A did not provide concerning
        design data timely and exactly, Party B could postpone the delivered date
        and
        get redesign fee calculated with actual losing day and RMB2,000 every day
        paid
        by Party A.

      6.3  
        Party A pays penalty bonds according to the Bank’s regulation of delayed
        payments if Party A cannot pay according to the contract.

      6.4  
        Because of delaying the delivered date, Party B should pay the penalty bonds
        to
        Party A which is 3% from design fee every postponed day. 

      6.5  
        Party B should continue to perfect the design if the rework could attributed
        to
        his bad design and reduce or remit the design fee according to the loss.
        For
        important quality accident produced by Party B, Party B should pay the
        compensation up to direct loss at a rate of3:1.

      7.   
        Others

       

      This
        Contract shall be effective after both parties have signed it until the total
        design was finished. Any supplement must be through both parties’ negotiation
        and agreement. The supplementary agreement has the equal effect but cannot
        conflict with this Contract.

      

      Any
        dispute arising from the execution shall be settled through friendly
        consultations between both parties. In case of no settlement can be settled
        through consultations, the dispute shall be: (1)submitted for arbitration,
        (1)prosecute directly to People’s Court.

      

       

      This
        Contract has 4 versions, each party owns 2 versions.

      

      

      Party
        A:
        Shannxi Kai Da Lv You Gu Wen You Xian Gong Si

       

      /s/
        Lei, Ming

      Lei,
        Ming

       

      Party
        B:
        Wu, Lianshe

      

      /s/
        Wu, Lianshe

      Wu,
        Lianshe

       

      Date:
        September 25, 2005.Exhibit 10.7

    Exhibit
      10.7

     

    CONSULTING
      SERVICES AGREEMENT

    

    September
      15, 2005

    

    

    PERSONAL
      AND CONFIDENTIAL

    

    Shanxi
      Kai Da Lv You Gu Wen You Xian Gong Si

    E
      Pang Gong Site, 44 Hong Guang Road

    Xi’An,
      P.R.China

    Attn:
      Ke,
      Xian Yan

    

    Dear
      Ms.
      Ke,

    

    This
      service agreement ("Agreement") confirms the terms and conditions of the
      engagement of Chris Cottone and Weixuan Luo (collectively the "Retainees")
      by
      Shanxi Kai Da Lv You Gu Wen You Xian Gong Si (the
      "Company") to render certain consulting services to the Company in connection
      with the Company's plans to shift their accounting systems to a format that
      is
      consistent with United States GAAP (Generally Accepted Accounting Principles),
      and related upgrades and modifications to management training and business
      plan
      development that will more readily integrate with United States
      GAAP.

    

    	1.  	
            Services.
              Retainees agree to perform the following
              services:

          

    

    	(a)  	
            Advise
              and assist the Company in the conversion of its financial reporting
              systems, including its projected financial statements, to a format
              that is
              consistent with United States GAAP (Generally Accepted Accounting
              Principles);

          

    

    	(b)  	
            Review
              and advise the Company on all documents and accounting systems relating
              to
              its finances and transactions, with the purpose of bringing such documents
              and systems into compliance with United States
              GAAP;

          

    

    	(c)  	
            Advise
              and assist the Company with the design and preparation of a business
              plan
              in a format generally consistent with the financial standards applicable
              in the United States;

          

    

    	(d)  	
            Advise
              and assist the Company with redesigning its capital structure, consistent
              with United States GAAP and usual and customary business practices
              for
              companies similar to the Company; 

          

    

    	(e)  	
            Advise
              and assist with the preparation of English-version marketing materials
              for
              the Company’s products; 

          

    

    	(f)  	
            Provide
              necessary consulting services and support as an international liaison
              for
              Company to third-party service providers, including coordination amongst
              the Company and their related attorneys and
              CPAs;

          

    

    	(g)  	
            Provide
              management training to the senior management of the Company, pertaining
              to
              usual and customary practices for U.S. companies with business plans
              similar to the Company’s business plan;

          

    	(h)  	
            Advise
              and train the Company on compliance filings with the United States
              Securities and Exchange Commission, including Forms 10-QSB, 10-KSB,
              and
              8-K and EDGAR filing of the same;

          

    

    	(i)  	
            Assist
              the Company in planning and conducting a dinner show which is going
              to be
              held at the theme park of the Company, including but not limited to,
              selecting suppliers, managing performance teams, performance quality
              controls;

          

    

    	(j)  	
            Perform
              such other services as the Company and Retainees shall mutually agree
              to
              in writing.

          

     

    
      
         

      

      
        1

        
          

        

      

      
         

      

    

     

    2. Fees.
      The
      Company agrees to pay Retainees for their services a consulting service fee
      of
      400,000 shares of the Company's freely tradable common stocks ("Service Fee")
      upon signing this Agreement.

    

    3. Term.
      The
      term of this Agreement shall commence on
      September 15, 2005 and end on
      September 15, 2006 (the "Term"). This Agreement may be renewed upon mutual
      written agreement of the parties hereto. The Company may terminate this
      agreement with 45 days prior written notice to Retainees. However, any
      obligation pursuant to this Paragraph 3, and pursuant to Paragraphs 2 (payment
      of fees), 5 (governing law), 8 (non-disclosure) and 9 (miscellaneous) hereof,
      shall survive the termination or expiration of this Agreement.

    

    4. Matters
      Relating to Engagement.
      The
      Company acknowledges that Retainees have been retained solely to provide the
      services set forth in this Agreement. In rendering such services, Retainees
      shall act as independent contractors, and any duties of Retainees arising out
      of
      its engagement hereunder shall be owed solely to the Company.

    

    The
      Company acknowledges that Retainees are consultants engaged in providing
      consulting services. The Company acknowledges and agrees that in connection
      with
      the performance of Retainees' services hereunder (or any other services),
      Retainees will not be providing the Company with legal, tax or accounting advice
      or guidance (and no advice or guidance provided by Retainees to the Company
      should be construed as such) and that Retainees will not hold themselves out
      to
      be advisors as to legal, tax, accounting or regulatory matters in any
      jurisdiction.

    

    The
      Company recognizes and confirms that in performing their duties pursuant to
      this
      Agreement, Retainees will be using and relying on data, material, and other
      information furnished by the Company, a third party provider, or their
      respective employees and representatives (“the Information”). The Company will
      cooperate with Retainees and will furnish Retainees with all Information
      concerning the Company and any financial information or organizational or
      transactional information which Retainees deems appropriate, and Company will
      provide Retainees with access to the Company's officers, directors, employees,
      independent accountants and legal counsel for the purpose of performing
      Retainees' obligations pursuant to this Agreement. The Company hereby agrees
      and
      represents that all Information furnished to Retainees pursuant to this
      Agreement shall be accurate and complete in all material respects at the time
      provided, and that, if the Information becomes materially inaccurate, incomplete
      or misleading during the term of Retainees' engagement hereunder, the Company
      shall promptly advise Retainees in writing. Accordingly, Retainees assume no
      responsibility for the accuracy and completeness of the Information. In
      rendering their services, Retainees will be using and relying upon the
      Information without independent verification evaluation thereof.

    

    5. Governing
      Law and Consent to Jurisdiction.
      This
      Agreement shall be governed by and construed in accordance with the laws of
      the
      State of Florida, including its conflict of laws provisions. Any dispute arising
      from or in connection with or in respect of the interpretation or application
      of
      this Agreement shall be submitted to one arbitrator appointed by the American
      Arbitration Association. The Arbitration will be conducted in compliance with
      the rules and procedures of the American Arbitration Association. The award
      of
      such arbitration shall be final and have binding force over each party, and
      judgment on such arbitration award may be entered in any court of competent
      jurisdiction.

    

    6. No
      Brokers.
      The
      Company represents and warrants to Retainees that there are no brokers,
      representatives or other persons which have an interest in compensation due
      to
      Retainees from any services contemplated herein. 

    

    7.
      Authorization.
      The
      Company and Retainees represent and warrant that each has all requisite power
      and authority, and all necessary authorizations, to enter into and carry out
      the
      terms and provisions of this Agreement and the execution, delivery and
      performance of this Agreement does not breach or conflict with any agreement,
      document or instrument (including contracts, wills, agreements, records and
      wire
      receipts, etc.) to which it is a party or bound.

     

    
      
         

      

      
        2

        
          

        

      

      
         

      

    

     

    8. Non-disclosure
      All the
      Terms and Conditions set forth in this contract are regarded as Confidential
      Subject Matter. Both
      Retainees and the Company agree to hold in confidence all Confidential Subject
      Matter; to not disclose any Confidential Subject Matter to any third party;
      to
      use Confidential Subject Matter solely for the Project; and to disclose such
      Confidential Subject Matter only to individuals within receiving Party’s
      organization that are directly involved with the Project on a need-to-know
      basis.

     

        Unless
      otherwise specified in writing, all Confidential Subject Matter remains the
      disclosing Party's property. Upon request of the disclosing Party, the receiving
      Party agrees to return or destroy all Confidential Subject Matter received
      from
      the disclosing Party, except for one copy, which the receiving Party may keep
      solely to monitor its obligations under this Agreement. The party
that
      violates the term hereto shall indemnify the other party for any damage
      therefore arises. 

    

    9. Miscellaneous.
      This
      Agreement constitutes the entire understanding and agreement between the Company
      and Retainees with respect to the subject matter hereof and supersedes all
      prior
      understandings or agreements between the parties with respect thereto, whether
      oral or written, express or implied. Any amendments or modifications must be
      executed in writing by all parties. This Agreement and all rights, liabilities
      and obligations hereunder shall be binding upon and inure to the benefit of
      each
      party’s successors but may not be assigned without the prior written approval of
      the other party. If any provision of this Agreement shall be held or made
      invalid by a statute, rule, regulation, decision of a tribunal or otherwise,
      the
      remainder of this Agreement shall not be affected thereby and, to this extent,
      the provisions of this Agreement shall be deemed to be severable. This Agreement
      may be executed in any number of counterparts, each of which shall be deemed
      to
      be an original, but such counterparts shall, together, constitute only one
      instrument. The descriptive headings of the Paragraphs of this Agreement are
      inserted for convenience only, do not constitute a part of this Agreement and
      shall not affect in any way the meaning or interpretation of this
      Agreement.

    

    If
      all
      parties agree in writing, they can make supplementary agreements for those
      unsettled issues between them, which signed writings will be binding on all
      parties.

    

    Please
      confirm that the foregoing correctly sets forth our agreement by signing below
      in the space provided and returning this Agreement to Retainees for execution,
      which shall constitute a binding agreement as of the date first above
      written.

    

    Thank
      you. We look forward to a mutually rewarding relationship.

    

    

    Chris
      Cottone

    (Individually)

    

    

    By:
      /s/ Chris Cottone 

    Name:
      Chris Cottone

    

    

    Weixuan
      Luo

    (Individually)

    

    

    By:
      /s/ Weixuan Luo 

    Name:
      Weixuan Luo

    

    

    AGREED
      TO
      AND ACCEPTED

    AS
      OF
      September 15, 2005

    

    

    Shanxi
      Kai Da Lv You Gu Wen You Xian Gong Si

    

    

    By:
      /s/ Ke, Xian Yan

    Name:
      Ke,
      Xian Yan

    Title:
      President

    

    

    AGREED
      TO
      AND ACCEPTED

    AS
      OF
      September 15, 2005

     

     

    
      
         

      

      
        3

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00102-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00102-of-00352.parquet"}]]