Document:

<PAGE>

                        SUBLEASE AND CONSENT TO SUBLEASE

       This Sublease and Consent to Sublease (the "Sublease") is made and
entered into this Eleventh day of November 1999 by and between, EXE
TECHNOLOGIES, INC., a Delaware corporation with offices located at 8787 Stemmons
Freeway, Dallas, Texas 75247, herein referred to as "Sublessor", and FRITZ
COMPANIES, INC., a Delaware corporation, with headquarters located at 706
Mission Street, San Francisco, California 94103, herein referred to as
"Sublessee" (Sublessor and Sublessee each a "Party" and collectively the
"Parties").

       WHEREAS, Sublessor is the lessee of the real estate located at 8777
Stemmons Freeway, Dallas, Texas (the "Demised Premises") by virtue of a lease
agreement dated May 18, 1999 (the "Master Lease") by and between Sublessor, as
Tenant or Lessee, and BLI-8787, LTD., as Lessor or Landlord (the "Master
Lessor").

       WHEREAS, Sublessee desires to obtain space on or in the Demised Premises,
and Sublessor desires to sublease space to Sublessee, all on the terms and
conditions herein set forth,

       NOW THEREFORE, the Parties, intending to be legally bound, hereby
agree as follows:

1. GRANT AND PREMISES. For and in consideration of the Rent to be paid by
Sublessee and the other covenants and agreements herein contained to be
performed by Sublessee, Sublessor hereby leases to Sublessee and Sublessee lets
from Sublessor that part of Demised Premises consisting of approximately 38,800
rentable square feet of space, more particularly identified on Exhibit A
attached hereto and made a part hereof ("Subleased Premises"). The rent stated
herein is for the Subleased Premises as a whole regardless of actual square
footage.

2. TERM. The Initial Term of this Sublease shall commence on First day of
December 1999 ("Sublease Commencement Date") and shall expire twenty-four (24)
months thereafter, ("Sublease Expiration Date"), unless sooner terminated or
extended as herein set forth.

3. MASTER LEASE. Sublessee acknowledges and agrees that Sublessor is the tenant
under the Master Lease, a copy of which is attached hereto as Exhibit B. This
Sublease is subject and subordinate to the Master Lease. The terms, conditions
and respective obligations of Sublessor and Sublessee to each other under this
Sublease shall be the terms and conditions on the Master Lease except to those
provisions of the Master Lease which are contradicted by this Sublease, in which
event the terms of this Sublease shall control over the Master Lease. In
addition, but not by way of limitation, the following provisions of the Master
Lease shall not apply to the rights and obligations of Sublessor and Sublessee:
Section 1, Section 3.3, Section 14.5, Section 16.4, Section 16.5 and Section
16.26. For the purposes of this Sublease, wherever in the Master Lease the word
"Lessor" or "Landlord" is used it shall be deemed to mean the Sublessor herein
and wherever in the Master Lease the word "Lessee" or "Tenant" is used it shall
mean the Sublessee herein. During the term of this Sublease and any extensions
or renewals hereof and for all periods subsequent for obligations which have
arisen prior to the termination or expiration of this Sublease, Sublessee
covenants and agrees to assume, abide by and respect all terms of the Master
Lease, excepting those clauses relating to the payment of rent and term or which
are inconsistent with this Sublease. Sublessee agrees to execute any documents
required to demonstrate subordination of this Sublease to the Master Lease or to
make this Sublease subordinate to the lien of any ground lease, mortgage, deed
of trust, or security deed, as the case may be, including specifically a
subordination, non-disturbance and attornment agreement. If requested to do so,
Sublessee agrees to attorn to any person or other entity that acquires title to
the real property encompassing the Subleased Premises, whether through judicial
foreclosure, sale under power, or otherwise, and to any assignee of such person
or other entity, provided that the entity requesting such attornment agrees to
not disturb Sublessee's rights hereunder.

4. CONSENT OF MASTER LESSOR. In the event that the Master Lease requires that
the Sublessor obtain the consent of the Master Lessor or any other party to
sublet, then this Sublease shall not be effective unless, within ten (10) days
of the date of the signature of Sublessor or Sublessee of this Sublease,
whichever is later, the Master Lessor and any other party required by the Master
Lease has given its written consent to sublease.

5. ACCEPTANCE OF PREMISES. Sublessee's acceptance of possession of Subleased
Premises shall be evidence that Sublessee has inspected the Subleased Premises,
that the Subleased Premises are in good order and satisfactory condition at the
time of possession thereof, and that the Sublessee accepts the Subleased
Premises in its present condition, latent defects excepted.

6. BASE RENT. Sublessee shall pay to Sublessor a Base Rent in the amount of
$79,216.67 per month during the Initial and any Renewal Term. The first such
payment shall be due upon the Sublease Commencement Date and a like monthly
installment shall be due and payable, without demand, deduction or setoff, on or
before the first day of each calendar month succeeding the Sublease Commencement
Date, except that all payments due hereunder for any fractional calendar month
shall be prorated. Sublessor shall receive payment of Base Rent and other
charges on or before the due date at the address for notice given below.

7. ADDITIONAL RENT. Sublessee agrees to pay to Sublessor upon demand therefor,
as additional rent, Sublessee's pro rata share of any Excess Real Estate Taxes
and Excess Operating Expenses, as these terms are defined in the Master Lease
and as modified below. Sublessee's prorated amount shall be determined on the
basis of the size of the Subleased Premises. The Parties hereby agree that
Sublessee's pro rata share of any Excess Real Estate Taxes and Excess Operating
Expenses shall be deemed to be percent (19.4%). Notwithstanding anything in the
Master Lease to the contrary, and notwithstanding Master Lease Section 5.1 in
particular, Operating Expenses shall include all electricity, gas, steam, water,
sewer and other utility charges, none of which shall be charged directly to
Sublessee. Notwithstanding anything in Master Lease Section 2.2 to the contrary,
the base year for the purpose of calculating Excess Real Estate Taxes shall be
the calendar Year 2000. The base period for calculating Excess Operating
Expenses in any Sublease Year shall be the sum of the Operating Expenses,
including utilities as noted above, incurred during the first twelve (12) months
after the Sublease Commencement Date. Notwithstanding anything in the Master
Lease to the contrary, and notwithstanding master Lease Section 9.1 in
particular, this Section 7 sets forth the entire financial obligation of
Sublessee beyond Base Rent, it being the intent of the Parties that this is a
fully serviced Sublease. Sublessee shall pay Base Rent and Additional Rent
without demand or setoff.

8. RENT ABATEMENT. Notwithstanding anything else in this Sublease to the
contrary, Sublessor agrees that, as a material consideration for entering into
this Sublease by Sublessee, Base Rent shall abate during the first three (3)
months of the Initial Term (the "Rent Abatement Period").

9. TELECOMMUNICATIONS/SUBLESSOR'S WORK. Subject to Article 8 of the Master
Lease, Sublessor at Sublessor's expense shall timely complete the improvements
set forth in Exhibit C ("Sublessor's Work"). The timetable for the completion of
telecommunications alterations set forth in Exhibit C is not merely a recital
but is a material consideration for Sublessee's execution of this Sublease, the
parties intending to be legally bound thereby. Sublessee shall reimburse
Sublessor for all one time costs associated with the conversion of the
telecommunications switch to a multi-tenant status. Sublessee shall have the
right to amortize at an interest rate of fifteen percent (15%) up to fifty
percent (50%) of the one time costs associated with the conversion of the
telecommunications switch to a multi-tenant status over the two year term of the
Sublease, the remainder will be payable upon receipt of an itemized bill.
Sublessee shall also reimburse Sublessor for its proportionate share of existing
amortization costs related to the Sublessor's prior purchase of the

                                   PAGE 1 OF 4

<PAGE>

telecommunications switch. Sublessor shall provide to Sublessee all pertinent
documentation to demonstrate Sublessor's actual costs thereof. "Proportionate
Share" shall be defined as the percentage of the Sublease Premises versus the
entire Premises. The Proportionate Share shall be calculated by dividing the
area of the Subleased Premises by the area of the entire premises. (Estimated:
38,800/200,000 = .1940 or 19.40%). Sublessee shall have the exclusive use of the
entire telecommunications switch and related systems as they relate to the
Subleased Premises, provided however, that Sublessee shall not have physical
access to the switch and related systems unless accompanied by Sublessor
personnel, which Sublessor shall make reasonably available, taking into
consideration time, place and manner.

10. DELAYED OCCUPANCY. Any delay in occupancy of the Subleased Premises by
Sublessee shall not operate to abate Sublessee's rental obligation hereunder
unless such delay is caused by the fault of Sublessor, or any of its
contractors, agents or employees. Any delay in occupancy of the Subleased
Premises for any reason shall not operate to extend the Sublease Expiration
Date.

11. FAILURE TO DELIVER SUBLEASED PREMISES. Sublessor shall make available to
Sublessee the Subleased Premises on the Sublease Commencement Date in clean
condition and good working order, with all facilities, including plumbing,
electrical fire sprinkler, lighting, air conditioning, heating, elevators,
washrooms, telecommunications items listed in Exhibit C and loading doors, if
any, in good working condition. In the event that the Subleased Premises are not
ready for occupancy by Sublessee on the Sublease Commencement Date, or in the
event of Sublessor's failure to timely complete Sublessor's Work, and except if
any such delay is caused by Sublessee or Sublessee's agents, as Sublessee's sole
remedy the Rent Abatement Period shall be extended by the same number of days as
any such delay continues. In the event that Sublessor has not completed
Sublessor's Work or the Subleased Premises are not ready for occupancy by
Sublessee on or before December 15, 1999, and except if the failure is caused by
Sublessee or Sublessee's agents, Sublessee may, at Sublessee's option and in
addition to any other remedies that may be available to Sublessee at law or in
equity (which shall not include consequential or punitive damages but may
include costs of mitigation such as increased cost of alternative space), advise
Sublessor in writing that Sublessee elects to terminate this Sublease, in which
event this Sublease shall be cancelled and thereupon become null and void, and
any Base Rent or other payment paid by Sublessee to Sublessor shall be refunded
to Sublessee.

12. PERMITTED USES. Sublessee shall use and occupy Subleased Premises only for
general office and related uses, and in accordance with all applicable laws,
ordinances and governmental regulations. Sublesse shall not use the Subleased
Premises for "Public Accommodation" under the Americans with Disabilities Act.
Sublessee shall not make any alterations to the Subleased Premises.

13. COMMON AREAS. All areas situated within Demised Premises that are designated
by Sublessor for common use by Sublessor, Sublessee, other sublessees of the
Demised Premises, and their respective customers, guests and invitees are herein
collectively referred to as "Common Areas". Sublessee's permitted employees,
agents, customers, guests and invitees shall have the non-exclusive right, in
common with Sublessor and all other Sublessees of the Demised Premises, and
their respective employees, agents, customers, guests and invitees, to use
Common Areas.

14. USE OF PARKING AREAS. If a part of the Common Areas is designed to provide
off-street parking for the common use by Sublessor and all sublessees of the
Demised Premises and their respective employees, agents, customers, guests and
invitees, Sublessor agrees that there shall nevertheless be available at all
times to Sublessee, for the use of its employees, agents, customers guests and
invitees, no fewer than one hundred fifty five (155) parking spaces in the
parking area. Surface spaces will be free of charge, and Sublessee shall have
the option to utilize up to twenty (20) garage spaces at a cost of fifteen
dollars ($15) per garage space per month. Sublessee agrees that it shall not use
any part of parking area or permit the use thereof in a manner that will
obstruct driveways serving parking areas.

15. FURNITURE. As a material consideration for entering into this Sublease by
Sublessee, Sublessee shall have full and exclusive use of the office furniture
and fixtures listed in Exhibit A, excluding furniture and fixtures shown in the
conference rooms and offices, for the duration of the Initial and any Renewal
Term. Sublessee shall use such furniture only for its intended purpose and shall
maintain such furniture in the same condition as at the Sublease Commencement
Date, reasonable wear and tear excepted. At the expiration of the Initial Term
or the Renewal Term, Sublessor shall take possession of such furniture at its
expense. Sublessor warrants that it is the lawful and rightful owner of such
furniture and that such furniture is not subject to the security interest of
another party, is not collateral to secure any debt or obligation of Sublessor
or any other party, and that Sublessor shall not use such furniture as
collateral during the Initial or any Renewal Term. Sublessor shall defend,
indemnify and hold harmless Sublessee for any breach of this warranty. Upon
approval by Master Lessor of sublease of the Subleased Premises by Sublessor to
Sublessee, Sublessee shall pay to Sublessor the amount of Twenty Five Thousand
dollars ($25,000) to be used as a Security Deposit on the furniture to be used
by Sublessee during the term of this Sublease. Said Security Deposit shall be
returned to Sublessee upon the termination of this Sublease and the surrender of
the furniture by Sublessee. Deductions from the Security Deposit shall only
occur in the event any furniture is missing, or in the event Sublessee has
caused damage to the furniture beyond normal wear and tear, and in such an event
the deduction will be limited to the then current value of the furniture in
question absent such damage.

16. INSURANCE. Sublessee shall procure and maintain during the term of this
Sublease, at its own cost and expense, a policy or policies of General Public
Liability Insurance insuring Sublessee, and Sublessor and Master Lessor as
additional insureds, against claims for personal injury, including death, and
property damage, including loss of use thereof, in limits of not less than those
set forth in Article 6.4 of the Master Lease. Sublessee shall also carry Workers
Compensation Insurance in accordance with statutory limits. Certificates of such
insurance policies shall be delivered to Sublessor upon request. Sublessor shall
procure and maintain (or ensure that Master Lessor procures and maintains)
during the term of this Sublease, at its own cost and expense, a policy or
policies of insurance insuring the Demised Premises for the benefit of Sublessee
in an amount equal to the full replacement value thereof against loss or damage
by the perils commonly insured under an "all risk" type insurance policy
(including but not necessarily limited to fire, windstorm, hail, explosion,
vandalism, malicious mischief, civil commotion or unrest,) and such other risks
as now are or may be customarily covered with respect buildings and improvements
similar in construction, general location, use, occupancy and design as the
Demised Premises ("Insured Perils").

17. WAIVER OF SUBROGATION. In the event the Demised Premises suffer any loss or
damage or expense resulting from an Insured Peril; and either Sublessor or
Sublessee, as the case may be, is required to insure the Demised Premises in
whole or in part for such loss, cost, damage or expense (or is required to
ensure that Master Lessor insures the Demised Premises); then the party so
insured or required to be insured (including Sublessee, Sublessor and Master
Lessor) hereby releases the other party from any liability it may have on
account of such loss, cost, damage or expense to the extent of any amount
recovered by reason of such insurance, and waives any right of subrogation which
might otherwise exist in or accrue to any person on account thereof.

18. PERSONAL PROPERTY TAXES. During the term hereof Sublessee shall pay, prior
to delinquency, all taxes assessed against and levied upon the fixtures,
furnishings, equipment, and all other personal property of Sublessee contained
in the Subleased Premises and, when possible, Sublessee shall cause said
fixtures, furnishings, equipment and all other personal property of Lessee
contained in Subleased Premises to be assessed and billed separately from the
real property of Sublessor or Master Lessor. In the event any or all of
Sublessee's fixtures, furnishings, equipment and other personal property shall
be assessed and taxed with Sublessor's or Master Lessor's real property, the
Sublessee shall pay to Sublessor or Master Lessor its share of such taxes within
thirty (30) days after delivery to Sublessee by Sublessor or Master Lessor of a
statement in writing setting forth the amount of such taxes applicable to
Sublessee's property. For the purpose of determining said amount, figures
supplied by the County Assessor as to the amount so assessed shall be
conclusive. Sublessee shall comply with the

                                   PAGE 2 OF 4

<PAGE>

provisions of any law, ordinance or rule of the taxing authorities, which
requires Sublessee to file a report of Sublessee's property located in the
Subleased Premises.

19. QUIET ENJOYMENT. Sublessee shall not use, nor shall permit the Leased
Premises to be used, nor shall its employees, agents, guests or invitees commit
any act which may interfere with the right to the quiet enjoyment of any other
tenant in the Subleased Premises and so long as Sublessee pays rent and complies
with all other obligations of this Lease, Sublessee shall quietly and peacefully
have, hold, and enjoy the Leased Premises, and neither Sublessor nor Master
Lessor, nor anyone claiming by, through or under Sublessor or Master Lessor,
shall disturb Sublessee's quiet and peaceful possession of its Leased Premises.
Sublessor warrants that it shall not cause, through action or inaction, the
Master Lease to be terminated prior to the expiration of the Initial Term or any
Renewal Term. Sublessor shall indemnify Sublessee for any costs, damages or
expenses arising out of or related to its breach of said warranty.

20. NOTICE. Any and all notice required or agreed to be given pursuant hereto
shall be sufficient if in writing and mailed by United States Certified or
Registered Mail, postage prepaid, addressed to Sublessor and Sublessee as
follows:

           If to Sublessor, at:                 If to Sublessee, at:

           EXE Technologies, Inc.               Fritz Companies, Inc.
           8787 Stemmons Freeway                706 Mission Street
           Dallas, Texas 75247                  San Francisco, CA  94103
           Attn.:  C.F.O.                       Attn.:  Director, Real Estate

21. BROKER COMMISSION. Each party represents to the other that Jackson &
Cooksey, acting on behalf of Sublessor, and Cushman & Wakefield acting on behalf
of Sublessee, are the only brokers in this transaction and that no other brokers
or person are entitled to any leasing commission or other compensation as a
result of the negotiation and execution of this Lease. Sublessor shall pay all
brokerage fees in the amount of Four Percent (4%) of the aggregate rentals for
the Initial Term. In the event that Sublessor fails to so pay the brokers,
Sublessee shall have the right to pay the brokers and deduct the payment from
the Base Rent or other payment obligations due Sublessor. All terms and
conditions of the brokerage fees to be paid by Sublessor to Cushman & Wakefield
are defined in a separate commission agreement.

22. RENEWAL OPTIONS. Provided this Sublease is then in effect and provided
Sublessee is not then in default of this Sublease, Sublessee shall have the
right, in its sole and absolute discretion, to renew this Sublease for one
additional term not to exceed fifteen (15) months (the "Renewal Term") on the
same terms and conditions as herein set forth. Sublessee shall exercise such
option by providing written notice to Sublessor of its intention no later than
one hundred twenty (120) days prior to the expiration of the Initial Term. The
duration of the Renewal Term shall be elected by Sublessee at the time of the
exercise of the option. In the event Sublessee fails to timely notify Sublessor,
Sublessee's renewal option shall terminate and this Sublease shall expire on the
Sublease Expiration Date. Provided this Sublease is then in effect and provided
Sublessee is not then in default of this Sublease, Master Lessor, by its
signature below, hereby consents to such renewal by Sublessee, no additional
approval of Master Lessor being necessary.

23. RIGHT OF FIRST REFUSAL OPTION. Provided this Sublease is then in effect and
provided Sublessee is not then in default of this Sublease, and subordinate to
Voicestream's "Right of First Refusal", Sublessor agrees that, in the event
additional space leased by Sublessor in the Demised Premises is or becomes
available during the Initial or Renewal Term of this Sublease, Sublessee shall
have a right of first refusal to expand into such additional space for use by
Sublessee or any affiliate controlled by Sublessee; provided, however, that
Sublessor shall have the right to itself occupy or leave such space vacant
without obligation therefor to Sublessee. Sublessee shall have the right to
occupy such additional space upon the same terms as are offered by Sublessor to
any third party. Sublessor shall notify Sublessee in writing promptly upon
becoming aware of the availability of additional space. Sublessor shall further
notify Sublessee of any acceptable bona fide offer to lease such additional
space, and shall advise Sublessee of the material terms of such offer. Sublessee
shall exercise its right of first refusal by notifying Sublessor of its
intention within fifteen (15) days after receiving written notice of the
material terms of such bona fide offer. In the event Sublessee fails to notify
Sublessor within such fifteen-day period, Sublessee's right of first refusal for
such additional space shall terminate, but such termination shall be without
prejudice to Sublessee's right of first refusal for such space should it again
become available during the Initial or Renewal Term of this Sublease, or should
the terms under which the additional space is actually leased differ materially
from the bona fide offer (without limitation, any change in description, price
or term to be deemed material), and is without prejudice to Sublessee's right of
first refusal for any other additional space leased by Sublessor in the Demised
Premises. Sublessee shall be under no obligation to lease any additional space
that becomes available.

24. TIME OF THE ESSENCE. The Parties agree that time is of the essence in
performance of the obligations set forth herein.

25. GOVERNING LAW. This Sublease shall be governed and construed in accordance
with the laws of the state governing the Master Lease.

26. ENTIRE AGREEMENT. This instrument, along with any exhibits and attachments
hereto, constitutes the entire agreement between Sublessor and Sublessee
relative to the Subleased Premises. This Sublease and any exhibits and
attachments may be altered, amended or revoked only by an instrument in writing
signed by both Sublessor and Sublessee and approved by Master Lessor. Sublessor
and Sublessee agree hereby that all prior and contemporaneous oral agreements
between and among themselves and their agents or representatives relative to the
leasing of the Subleased Premises are merged in or revoked by this Sublease.

27. RIGHT TO SUBLEASE. Sublessee shall be permitted to assign or sublease all or
any portion of the premises, subject to the approval of Master Lessor (as
required by Article 10 of the Master Lease) and the approval of Sublessor, which
Sublessor approval shall not be unreasonably withheld or delayed.

28. SIGNAGE. Sublessee at Sublessee's expense shall be allowed to construct
monument signage with Sublessor's and Master Lessor's prior approval. The
specifications of such signage shall comply with all municipal codes and
regulations and with the Master Lease.

29. MOVE IN. Move in hours will be Monday through Friday 6:00 p.m. to 6:00 a.m.,
and at any times during the weekend.

            IN WITNESS WHEREOF, Sublessor and Sublessee have executed or caused
this Sublease to be executed, and Master Lessor has consented and agreed to this
Sublease, effective as of the day first above written.

SUBLESSEE
FRITZ COMPANIES, INC.

By: /S/ [ILLEGIBLE]
   -------------------------

Name:  -------------------------

Title: -------------------------

Date:  -------------------------

                                   PAGE 3 OF 4

<PAGE>

SUBLESSOR
EXE TECHNOLOGIES, INC.

By: /S/ CHRISTOPHER F. WRIGHT
   -----------------------------------

Name: CHRISTOPHER F. WRIGHT
     ---------------------------------

Title: SVP, ADMINISTRATION
      --------------------------------

Date:  11/15/99
     ---------------------------------

THIS SUBLEASE IS EXECUTED BY BLI-8787, LTD. ("MASTER LESSOR") SOLELY TO EVIDENCE
THE CONSENT OF MASTER LESSOR TO THE SUBLEASE BETWEEN SUBLESSOR AND SUBLESSEE;
PROVIDED, NOTHING HEREIN SHALL IN ANY WAY CHANGE THE TERMS, PROVISIONS AND
CONDITIONS OF THE MASTER LEASE. MASTER LESSOR HEREBY AGREES THAT SUBLESSEE SHALL
RECEIVE FROM MASTER LESSOR THE SAME WRITTEN NOTICE OF DEFAULT AS PROVIDED TO
SUBLESSOR PURSUANT TO ARTICLE 14 OF THE MASTER LEASE .

----------------------------------------------
BLI-8787, LTD Master Lessor

By:  BARNETT LANE INVESTMENTS, INC.
      GENERAL PARTNER

By:   /S/ DAVID A. LANE
   -----------------------------------

Name:   DAVID A. LANE
     ---------------------------------

Title:    PRESIDENT
      --------------------------------

Date:   11-17-99
     ---------------------------------

                                   PAGE 4 OF 4

<PAGE>

                                    EXHIBIT A

                                 [PREMISES MAP]

<PAGE>

                                   EXHIBIT B

                            [Master Lease Agreement]

<PAGE>

                                    Exhibit C

                                SUBLESSOR'S WORK

The following describes telecommunications services that will be provided by EXE
Technologies and timeframes for their delivery

December 1
1) 250 individual phone sets (multi-line 8 button handsets)
2) Voice-mail capability for all phone sets
3) Up to 50 analog lines for fax and modem
4) Extending of D-mark from computer room to third floor IDF
5) Category 5 cabling between the third and fourth floor IDFs.

January 1
1) 100 concurrent phone call capability
2) ACD capability for all phone sets
3) 9 supervisor stations for the ACD
4) Adds, Moves, and Changes will be provided for Fritz on Tuesdays and
   Thursdays between the hours of 08:00am and 12:00pm Central time.
5) Up-time for phone systems of Sublessee shall be equal to up-time for phone
   systems of Sublessor in the Building, Sublessor to use best efforts to
   maximum up-time.

Fritz intends to install one T1 and one ISDN line for data communications
Fritz will provide router and LAN switches for third and fourth floor for data
connectivity

Initial

Fritz Companies, Inc.               EXE Technologies, Inc.

/S/ [ILLEGIBLE]                     /S/ CHRISTOPHER F. WRIGHT
-------------------------           -------------------------

                                    /S/ DAVID A. LANE
                                    -------------------------

<PAGE>

                      AMENDMENT NO. 1 TO SUBLEASE AGREEMENT

                  THIS AMENDMENT NO. 1 TO SUBLEASE AGREEMENT ("Sublease
Amendment") is made as of this 28th day of October, 1999, by and between EXE
Technologies, Inc., a Delaware corporation (the "Sublessor") and Cook
Inlet/Voicestream PCS, L.L.C., a Delaware limited liability company (the
"Subtenant").

                              W I T N E S S E T H:

                  WHEREAS, Sublessor and BLI-8787, Ltd. as landlord (the
"Landlord") entered into a lease dated May 18, 1999 (the "Lease") pursuant to
which Landlord leased to Sublessor and Sublessor leased from Landlord certain
improved premises known as Floors 1-8 of Tower I of Regal Stemmons Corporate
Center, located at 8787 Stemmons Freeway, Dallas, TX and floors 1-5 of Tower II,
located at 8777 Stemmons Freeway, Dallas, TX (the "Premises"); and

                  WHEREAS, Sublessor and Subtenant have entered into a Sublease
Agreement dated as of July 7, 1999 (the "Sublease Agreement") pursuant to which
Sublessor leased to Subtenant and Subtenant leased from Sublessor a portion of
the Premises consisting of approximately 13,262 net rentable square feet on the
second floor of Tower II, as more fully set forth on Exhibit "A" attached hereto
(the "Subleased Premises"); and

                  WHEREAS, Sublessor and Subtenant desire to amend the Sublease
Agreement to provide for the sublease of additional space on the second floor of
Tower II.

                  NOW, THEREFORE, in consideration of the foregoing premises and
other good and valuable consideration, the receipt and sufficiency of which are
hereby acknowledged, and intending to be legally bound, the parties hereto agree
as follows:

                  1. SUBLEASE OF ADDITIONAL SPACE. Commencing November 1, 1999,
Sublessor desires to lease to Subtenant approximately 6,936 net rentable square
feet of additional air conditioned office space located on the second floor of
Tower II, as more fully set forth on Exhibit "B" attached hereto (the
"Additional Subleased Premises") for a base rent of $18.75 per

<PAGE>

rentable square feet annually, payable in accordance with the provisions of the
Sublease Agreement.

                  2. REMOVAL OF DEMISING WALLS. Prior to November 1, 1999,
Sublessor agrees to remove the two demising walls between the Subleased Premises
and the Additional Subleased Premises, at Sublessor's sole cost and expense.

                  3. DEFINITIONS. All terms used herein which are defined in the
Sublease Agreement shall have the respective meanings ascribed to such terms in
the Sublease Agreement.

                  4. OTHER TERMS AND CONDITIONS. All terms and conditions of the
Sublease Agreement not expressly altered by this Sublease Amendment shall
continue in full force and effect.

              [THE REMAINDER OF THIS PAGE INTENTIONALLY LEFT BLANK]

<PAGE>

                  IN WITNESS WHEREOF, the parties have executed this Sublease
Amendment the day and year first above written.

                                         SUBLESSOR:

                                         EXE TECHNOLOGIES, INC.

                                         By:  /S/ MICHAEL BURSTEIN
                                            ---------------------------

                                         Name:  MICHAEL BURSTEIN
                                              -------------------------

                                         Title:  CFO
                                               ------------------------

                                         SUBTENANT:

                                         COOK INLET/VOICESTREAM PCS, L.L.C.

                                         By:  VoiceStream PCS BTA I Corporation,
                                              its agent

                                         By:  /S/ [ILLEGIBLE]
                                            ----------------------------

                                         Name:
                                              --------------------------
                                         Title:
                                               -------------------------

<PAGE>

                               CONSENT OF LANDLORD

         Landlord consents to the subletting of the Additional Subleased
Premises from Sublessor to Subtenant in accordance with the terms and conditions
of the Sublease Agreement, as amended by this Amendment No. 1 to Sublease
Agreement, however, Sublessor shall continue to remain primarily liable for the
payment of all rent and other sums and the performance of all covenants required
of Sublessor under the Lease in accordance with the terms of the Lease.

                                    LANDLORD:

                                    BLI-8787, LTD.

                                    By:  Barnett Lane Investments, Inc.,
                                             general partner

                                    By:  /S/ DAVID A. LANE
                                       --------------------------------

                                    Name:  DAVID A. LANE
                                         ------------------------------

                                    Title:  PRESIDENT
                                          -----------------------------<PAGE>

                                  AGREEMENT OF LEASE

                                       BETWEEN

                            BALDWIN TOWERS ASSOCIATES, L.P.

                                     AS LANDLORD

                                         AND

                                Neptune Systems, Inc.

                                      AS TENANT

<PAGE>

                                     OFFICE LEASE

LEASE made this  3  day of  April , 1995 by and between  BALDWIN TOWERS
ASSOCIATES, L.P. (hereinafter called "Landlord"), and NEPTUNE SYSTEMS INC. a
Pennsylvania Corporation (hereinafter called "Tenant").

                                  WITNESSETH, THAT:

     1.   DEMISED PREMISES.  Landlord, for the term and subject to the
provisions and conditions hereof, leases to Tenant and Tenant accepts from
Landlord, the space consisting of 5,366 rentable square feet on the SEVENTH
floor known as Suite 700 (hereinafter referred to as the "Demised Premises")
of the building known as 1510 Chester Pike located in Eddystone, Pennsylvania
(hereinafter referred to as the "Building"), and more particularly described
by the cross-hatched area on the floor plans annexed herein as Exhibit "A",
to be used by Tenant for the purpose of GENERAL OFFICES AND SOFTWARE DESIGN
and for no other purpose.

     2.   TERM.  Tenant shall use and occupy the Demised Premises for a term
of TEN (10) years, commencing on the FIRST day of JULY, 1995 and ending on
the THIRTIETH day of JUNE,  2005  unless sooner terminated as herein provided.

     3.   MINIMUM RENT.

          (a)  See Rent Rider attached. The first installment to be payable
on the execution of this Lease and subsequent installments to be payable on
the first day of each successive month of term hereof following the first
month of such terms.

          (b)  If the term of this Lease begins on a day other than the first
day of a month, rent from such day until the first day of the following month
shall be prorated at the rate of one-thirtieth of the fixed monthly rental
for each day of the first full calendar month of the term hereof (and, in
such event, the installment of rent paid at execution hereof shall be applied
to the rent due for the first full calendar month of the term hereof).

          (c)  All rent and other sums due to Landlord hereunder shall be
payable to BALDWIN TOWERS ASSOCIATES. L.P. and mailed to the office of
Landlord at 555 NORTH LANE, SUITE 6101, CONSHOHOCKEN, PENNSYLVANIA, 19428, or
to such other party or at such other address as Landlord may designate, from
time to time, by written notice to Tenant, without demand and without
deduction, set-off or counterclaim (except to the extent demand or notice
shall be expressly provided for herein).

          (d)  If Landlord, at any time or times, shall accept said rent or any
other sum due to it hereunder after the same, shall become due and payable such
acceptance shall not excuse delay upon subsequent occasions, or constitute or be
construed as, a waiver of any of Landlord's rights hereunder.

                                 Page-2

<PAGE>

     4.   ESCALATION IN TAXES, OPERATING COSTS, COSTS OF LIVING: COST OF
ELECTRICITY.

          (a)  Definitions.   As used in this section 4, the following terms
shall be defined as hereinafter set forth.

          (i)  "TAXES" shall mean all real estate taxes and assessments, general
and special, ordinary or extraordinary, foreseen or unforeseen, imposed upon the
Building or with respect to the ownership thereof and the parcel of land
appurtenant thereto. If, due to a future change in the method of taxation, any
franchise, income, profit or other tax, however designated, shall be levied or
imposed in substitution in whole or in part, for (or in lieu of) any tax which
would otherwise be included within the defined herein.

          (ii)  "Base year operating expenses" shall be $3.50 per square foot.

          (iii) "TENANT'S FRACTION" shall be a fraction, the numerator of
which is the Demised Rentable Square Feet and the denominator of which is the
Rentable Square Feet in the Building. [5,366/175,878]

          (iv)  (A) "Operating Expenses" shall mean except as hereinafter
limited, Landlord's actual out-of-pocket expenses in respect of the
operation, maintenance and management of the Building (after deducting any
reimbursement, discount, credit, reduction or other allowance received by
Landlord) and shall include, without limitation: (1) wages and salaries (and
taxes imposed upon employers with respect to such employed by Landlord for
rendering service in the normal operation, cleaning, maintenance, and repair
of the Building: (2) contract costs of contractors hired for the operation,
maintenance and repair of the Building; (3) the cost of steam, electricity,
water and sewer and other utilities (except for electricity, which is
separately charged by Landlord as herein provided) chargeable to the
operation and maintenance of the Building; (4) cost of insurance for the
Building including fire and extended coverage, elevator, boiler, sprinkler
leakage, water damage, public liability and property damage, plate glass, and
rent protection, but excluding any charge for increased premiums due to acts
or omissions of other occupants of the Building or because of extra risk
which are reimbursed to Landlord by such other occupants; (5) supplies; and
(6) legal and accounting expenses; (7) real estate taxes (8) management
expense.

The term "Operating Expenses" shall not include: (1) the cost of redecorating
or repairing not provided on a regular basis to tenants of the Building; (2)
the cost of any repair or replacement item which, by standard accounting
practice, should be capitalized; (3) any charge for depreciation, interest or
rents paid or incurred by Landlord; (4) any charge for Landlord's income tax,
excess profit taxes, franchise taxes or similar taxes on Landlord's business;
(5) commissions.

          (B)  In determining Operating expenses for any year, if less than
ninety-five percent (95%) of the Building rentable area shall have been
occupied by tenants at any time during such year, Operating Expenses shall be
deemed for such year to be an amount equal to the like expenses which
Landlord reasonably determines would normally be incurred had such occupancy
been ninety-five percent (95%) throughout such year.

                                Page-3
<PAGE>

          (C)  If, after the Base Year for Operating Expenses, Landlord shall
eliminate any component of Operating Expenses, as a result of the introduction
of a labor saving device or other capital improvement, the corresponding item of
Operating Expenses shall be deducted from the Operating Expenses expended by
Landlord in said Base Year for purposes of calculating Tenant's Proportionate
Share of any increased Operating Expenses.

          (vi)  "DEMISED RENTABLE SQUARE FEET" shall mean 5,366 square feet.

          (vii) "RENTABLE SQUARE FEET IN THE BUILDING" shall mean 175,878 square
feet.

          (b)  Escalation of Operating Expenses

          (i)   For and with respect to each calendar year of the term of this
Lease (and any renewals or extensions thereof) subsequent to the Base Year for
Operating Expenses, there shall accrue, as additional rent, an amount equal to
the product obtained by multiplying the Tenant's Fraction by the amount of the
increase, if any, of Operating Expenses for such year over the Base Year
Operating Expenses (appropriately prorated for any partial calendar year
included within the beginning and of the term).

          (ii)  Landlord shall furnish to Tenant as soon as reasonably possible
after the beginning of each calendar year of the term hereof subsequent to the
Base Year for Operating Expenses;

          (A)  A statement (the "Expense Statement") setting forth (1) Operating
Expenses for the previous calendar year, and (2) Tenant's Fraction of the
Operating Expenses for the previous calendar year; and

          (B)  A statement of Landlord's good faith estimate of Operating
Expenses, and the amount of Tenant's Fraction thereof (the "Estimated Share"),
for the current calendar year.

          (iii) Beginning with the next installment of minimum rent due after
delivery of the foregoing statements to Tenant, Tenant shall pay to Landlord, on
account of its share of Operating Expenses (or Landlord shall pay to Tenant, if
the following quantity is negative):

          (A)  One-twelfth of the Estimated Share multiplied by the number of
full or partial calendar months elapsed during the current calendar year up to
and including the month payment is made, plus any amounts due from Tenant to
Landlord on account of Operating Expenses for prior periods of time, less:

          (B)  The amount, if any, by which the aggregate of payments made by
Tenant on account of Operating Expenses for the previous calendar year exceed
those actually due as specified in the Expense Statement.

                                 Page-4
<PAGE>

          (iv)  On the first day of each succeeding month up to the time Tenant
shall receive a new Expense Statement and statement of Tenant's Estimated Share,
Tenant shall pay to Landlord, on account of its share of Operating Expenses,
one-twelfth of the then current Estimated Share. Any payment due from Tenant to
Landlord, or any refund due from Landlord to Tenant, on account of Operating
Expenses not yet determined as of the expiration of the term hereof shall be
made within twenty (20) days after submission to Tenant of the next Expense
Statement.

     5.   UTILITIES SEPARATELY CHARGED TO DEMISED PREMISES. Tenant shall be
responsible for all utilities (including gas and electric) which are consumed
within the Demised Premises. If a separate meter is installed, Tenant shall
pay for the consumption of such utilities based on its metered usage. If no
meter is installed, Tenant shall pay a pro-rata share of any utility charges
covering the Demised Premises and other areas of the Building which pro-rata
share shall be based on the percentage which the Demised Rentable Square Feet
bears to the square footage of the areas of the Building serviced by such
utility. Utility bills shall be paid by Tenant within ten (10) days after the
receipt and non-payment or late payment of such bills shall be considered a
default under this Lease.

     6.   SECURITY DEPOSIT.  As additional security for the full and prompt
performance by Tenant of the terms and covenants of this Lease, Tenant has
deposited with the Landlord the sum of SIX THOUSAND TWO HUNDRED SIXTY DOLLARS
($6,260.00) which shall not constitute rent for any month (unless so applied by
Landlord on account of Tenant's default). Tenant shall, upon demand, restore any
portion of said security deposit which may be applied by Landlord to the cure of
any default by Tenant hereunder. To the extent that Landlord has not applied
said sum on account of a default, the security deposit shall be returned
(without interest) to Tenant promptly at termination of this Lease.

     7.   SERVICES.  Landlord agrees that it shall:

          (a)  Provide passenger elevator service to the Demised Premises during
all days with one (1) elevator subject to call at all other times. Tenant and
its employees and agents shall have access to the Demised Premises at all times,
subject to compliance with such security measures as shall be in effect for the
Building;

          (b)  Provide water for drinking, lavatory and toilet purposes drawn
through fixtures installed by Landlord; and

          (c)  Furnish the Demised Premises with electric for heating, hot and
chilled water and air-conditioning.  Tenant shall not install or operate in the
Demised Premises any electrically operated equipment or other machinery, other
than typewriters, adding machine and other machinery and equipment normally used
in modern offices, or any plumbing fixtures, without first obtaining the prior
written consent of the Landlord. Landlord may condition such consent upon the
payment by Tenant of additional rent as compensation for the additional
consumption of water and/or electricity occasioned by the operation of said
equipment, fixtures, or machinery.

                                   Page-5
<PAGE>

Tenant, at Tenant's sole expense, shall be responsible for the installation,
maintenance, and use of any equipment or any kind or nature whatsoever which
would or might necessitate any changes, replacements, or additions to the water
system, plumbing system, heating system, air-conditioning system, or the
electrical system servicing the Demised Premises or any other portion of the
Building without the prior written consent of the Landlord, and in the event
such consent is granted, such replacement, changes or additions shall be paid
for by Tenant. It is understood that Landlord does not warrant that any of the
services referred to in this Section 6 will be free from interruption from
causes beyond the reasonable control of Landlord. No interruption of service
shall ever be deemed an eviction or disturbance of Tenant's use and possession
of the Demised Premises or any part thereof or render Landlord liable to Tenant
for damages by abatement or rent or otherwise relieve Tenant from performance of
Tenant's obligations under this Lease, unless Landlord, after reasonable notice,
shall willfully and without cause fail or refuse to take action within its
control.

     8.   CARE OF DEMISED PREMISES. Tenant agrees, on behalf of itself, its
employees and agents, that it shall:

          (a)  Comply at all times with any and all federal, state and local
statutes, regulations, ordinances, and other requirements of any of the
constituted public authorities relating to its use and occupancy of the Demised
Premises;

          (b)  Give Landlord access to the Demised Premises at all reasonable
times, without charge or diminution of rent, to enable Landlord (i) to examine
the same and to make such repairs, additions and alterations as Landlord may be
permitted to make hereunder or as Landlord may deem advisable for the
preservation of the integrity, safety and good order of the Building or any part
thereof; and (ii) upon reasonable notice, to show the Demised Premises to
prospective mortgagees and purchasers and, during the six (6) months prior to
expiration of the term, to prospective tenants;

          (c)  Keep the Demised Premises in good order and condition and replace
all glass broken by Tenant, its agents, employees or invitees with glass of the
same quality as that broken, except for glass broken by fire and extended
coverage type risks, and commit no waste in the Demised Premises;

          (d)  Upon the termination of this Lease in any manner whatsoever,
remove Tenant's goods effects and those of any other person claiming under
Tenant, and quit and deliver up the Demised Premises to Landlord peaceably and
quietly in as good order and condition at the inception of the term of this
Lease or as the same hereafter may be improved by Landlord or Tenant, reasonable
use and wear thereof, damage from fire and extended coverage type risks, and
repairs which are Landlord's obligation excepted.  Goods and effects not removed
by Tenant at the termination of this Lease, however terminated, shall be
considered abandoned and Landlord may dispose of and/or store the same as it
deems expedient, the cost thereof to be charged to Tenant;

          (e)  Not place signs on the Demised Premises except on doors and then
only of a type and with lettering and text approved by Landlord. Identification
of Tenant and Tenant's location shall be provided in a directory in the Building
Lobby;

                               Page-6

<PAGE>

          (f)  Not overload, damage or deface the Demised Premises or do any
act which might make void or voidable any insurance on the Demised Premises
or the Building or which may render an increased or extra premium payable for
insurance (and without prejudice to any right or remedy of Landlord regarding
this subparagraph, Landlord shall have the right to collect from Tenant, upon
demand, any such increase or extra premium). Tenant shall maintain at its own
sole cost adequate insurance coverage for all of its equipment, furniture,
supplies and fixtures and provide Landlord with certificates evidencing such
coverage;

          (g)  Not make any alteration of or addition to the Demised Premises
without the prior written approval of Landlord (except for work of a
decorative nature);

          (h)  Not install or authorize the installation of any coin operated
vending machine, except for the dispensing of cigarettes, coffee, and similar
items to the employees of Tenant for consumption upon the Demised Premises;
and

          (i)  Observe the rules and regulations annexed hereto as Exhibit
"C", as the same may from time to time be amended by Landlord for the general
safety, comfort and convenience of Landlord, occupants and tenants of the
Building.

     9.   SUBLETTING AND ASSIGNING.  Tenant shall not assign this Lease or
sublet all or any portion of the Demised Premises without first obtaining
Landlord's prior written consent thereto. If such consent is given, it will
not release Tenant from its obligations hereunder and which will not be
deemed a consent to any further subletting or assignment. if Landlord
consents to any such subletting or assignment, it shall nevertheless be a
condition to the effectiveness thereof that a fully executed copy of the sub
lease or assignment be furnished to Landlord and that any assignee assume in.
writing all obligations of Tenant hereunder., Tenant shall not mortgage or
encumber this Lease.

     10.  DELAY IN POSSESSION.  If Landlord shall be unable to deliver
possession of the Demised Premises to Tenant on the date specified for
commencement of the term hereof because of the holding over or retention of
possession of any tenant or occupant, or if repairs improvements or
decoration of the Demised Premises are not completed, or for any repairs,
improvements or decoration of the Demised Premises are not completed, or for
any other reason. Landlord shall not be subject to any liability to Tenant
Under such circumstances, the rent reserved and covenanted to be paid herein
shall not commence until possession of Demised Premises is given or until
Landlord shall give written notice to Tenant that the Demised Premises are
available for occupancy by Tenant, whichever shall first occur, and no such
failure to give possession shall in any other respect affect the validity of
this Lease or any obligation to extend the term of this Lease.
Notwithstanding the foregoing, if Landlord fails to deliver possession to
Tenant by August 1, 1995, Tenant shall receive one day of free rent for each
day after August 1, 1995, that Tenant is delayed in obtaining possession.

     11.  FIRE OR CASUALTY.  In case of damage to the Demised Premises or the
Building by fire or other casualty, Tenant shall give immediate notice
thereof to Landlord. Landlord shall thereupon cause the damage to be repaired
with reasonable speed, subject to delays which may arise by reason of
adjustment of loss under insurance policies and for delays beyond the
reasonable control of Landlord. To the extent and for the time that the
Demised Premises are thereby rendered untenantable, the rent shall
proportionately abate.

                                    Page-7

<PAGE>

In the event the damage shall be so extensive that Landlord shall decide not
to repair or rebuild, or if any mortgagee, having the right to do so shall
direct that the insurance proceeds are to be applied to reduce the mortgage
debt rather than to the repair of such damage, this Lease shall, at the
option of Landlord, exercisable by written notice to Tenant given within
thirty (30) days after Landlord is notified of the casualty, be terminated as
of a date specified in such notice (which shall not be more than ninety (90)
days thereafter), and the rent (taking into account any abatement as
aforesaid) shall be adjusted to the termination date. Thereafter, Tenant
shall promptly vacate the Demised Premises.

     12.  LIABILITY. Tenant agrees that Landlord and its building manager and
their officers, employees and agents shall not be liable to Tenant, and
Tenant hereby releases said parties, for any personal injury or damage to or
loss of personal property in the Demised Premise from any cause whatsoever
unless such damage, loss or injury is the result of the willful and gross
negligence of Landlord, its building manager, or their officers, employees or
agents, and Landlord and its building manager and their officers or employees
shall not be liable to Tenant for any such damage or loss whether or not the
result of their willful and gross negligence to the extent Tenant is
compensated therefor by Tenant's insurance. Tenant shall and does hereby
indemnify and hold Landlord harmless of and from all loss or liability
incurred by Landlord in connection with any failure of Tenant to fully
perform its obligations under this Lease and in connection with any personal
injury or damage of any type or nature occurring in or resulting out of
Tenant's use of the Demised Premises, unless due to Landlord's fault.

     13.  EMINENT DOMAIN. If the whole or a substantial part of the Building
shall be taken or condemned for a public or quasi-public use under an statute
or by right of eminent domain or private purchase in lieu thereof by any
competent authority, Tenant shall have no claim against Landlord and shall
not have any claim or right to any portion of the amount that may be awarded
as damages or paid as a result of any such condemnation or purchase; and all
right of the Tenant to damages therefore are hereby assigned by Tenant to
Landlord.  The foregoing shall not, however, deprive Tenant of any separate
award for moving expenses or for any other award which would not reduce the
award payable to Landlord. Upon the date the right to possession shall vest
in the condemning authority, this Lease shall cease and terminate with rent
adjusted to such date, and Tenant shall have no claim against Landlord for
the value of any unexplored term of this Lease.

     14.  INSOLVENCY.

     (a) The appointment of a receiver or trustee to take possession of all
or a portion of the assets of Tenant, or (b) an assignment by Tenant for the
benefit of creditors, or (c) the institution by or against Tenant of any
proceedings for bankruptcy or reorganization under any state or federal law
(unless in the case of involuntary proceedings, the same shall be dismissed
within thirty (30) days after institution), or (d) any execution issued
against Tenant which is not stayed or discharged within fifteen (15) days
after issuance of any execution sale of the assets of Tenant, shall
constitute a breach of this Lease by Tenant. Landlord in the event of such a
breach, shall have, without need of further notice, the rights enumerated in
Section 15 herein.

                                    Page-8

<PAGE>

     15.  DEFAULT.

     (a)  If Tenant shall fail to pay rent or any other sum payable to
Landlord hereunder when due, or if Tenant shall fail to perform or observe
any of the other covenants, terms or conditions contained in this Lease
within fifteen (15) days (or such longer period as is reasonably required to
correct any such default, provided Tenant promptly commences and diligently
continues to effectuate a cure), but in any event within thirty (30) days
after written notice thereof by Landlord, or if any of the events specified
in Section 14 occur, or if Tenant vacates or abandons the Demised Premises
during the term hereof or removes or manifests an intention to remove any of
Tenant's goods or property therefrom other than in the ordinary and usual
course of Tenant's business, then and in any of said cases (notwithstanding
any former breach of covenant or waiver thereof in a former instance),
Landlord, in addition to all other rights and remedies available to it by law
or equity or by any other provisions hereof, may at any time thereafter:

          (i)  upon three (3) days notice to Tenant, declare to be
immediately due and payable, the rent and other charges herein reserved for
the balance of the term of this Lease (taken without regard to any early
termination of said term on account of default), a sum equal to the
Accelerated Rent Component (as hereinafter defined), and Tenant shall remain
liable to Landlord as hereinafter provided; and/or

          (ii) whether or not Landlord has elected to recover the Accelerated
Rent Component, terminate this Lease on at least five (5) days' notice to
Tenant and, on the date specified in said notice, this Lease and the term
hereby demised and all rights of Tenant hereunder shall expire and terminate
and Tenant shall thereupon quit and surrender possession of the Demised
Premises to Landlord in the condition elsewhere herein required and Tenant
shall remain liable to Landlord as hereinafter provided.

     (b)  For purposes herein, the Accelerated Rent Component shall mean the
aggregate of:

          (i)   all rent and other charges, payments, costs and expenses due
from Tenant to Landlord and in arrears at the time of the election of
Landlord to recover the Accelerated Rent Component;

          (ii)  the minimum rent reserved for the then entire unexpired
balance of the term of this Lease (taken without regard to any early
termination of the term by virtue of any default), plus all other charges,
payments, costs and expenses herein agreed to be paid by Tenant up to the end
of said term which shall be capable of precise determination at the time of
Landlord's election to recover the Accelerated Rent Component; and

          (iii) Landlord's good faith estimate of all charges, payments,
costs and expenses herein agreed to be paid by Tenant up to the end of said
term which shall not be capable to precise determination as aforesaid (and
for such purposes no estimate of any component of the additional rent to
accrue pursuant to the provisions of Section 4 hereof shall be less than the
amount which would be due if each such component continued at the highest
monthly rate or amount in effect during the twelve (12) months immediately
preceding the default).

                                    Page-9

<PAGE>

     (c)  In any case in which this Lease shall have been terminated, or in
any case in which Landlord shall have elected to recover the Accelerated Rent
Component and any portion of such sum shall remain unpaid, Landlord may
without further notice, enter upon and repossess the Demised Premises, by
force, summary proceedings, ejectment or otherwise, and may dispossess Tenant
and remove Tenant and al! other persons and property from the Demised
Premises and may have, hold and enjoy the Demised Premises and the rents and
profits therefrom. Landlord may, in its own name, as agent for Tenant, if
this Lease has not been terminated, or in its own behalf, if this Lease has
been terminated, relet the Demised Premises or any part thereof for such term
or terms (which may be greater or less than the period which would otherwise
have constituted the balance of the term of this Lease) and on such terms
(which may include concessions of free rent) as Landlord in its sole
discretion may determine. Landlord may, in connection with any such
reletting, cause the Demised Premises to be decorated, altered, divided,
consolidated with other space or otherwise changed or prepared for reletting.
No reletting shall be deemed a surrender and acceptance of the Demised
Premises.

     (d)  Tenant shall, with respect to all periods of time up to and
including the expiration of the term of this Lease (or what would have been
the expiration date in the absence of default or breach) remain liable to
Landlord as follows:

          (i)  In the event of termination of this Lease on account of
Tenant's default or breach, Tenant shall remain liable to Landlord for
damages equal to the rent and other charges payable under this Lease by
Tenant as if this Lease Were still in effect, less the net proceeds of any
reletting after deducting all costs incident thereto (including without
limitation all repossession costs, brokerage and' management commission,
operating and legal expenses and fees, alteration costs and expenses of
preparation for reletting ( and to the extent such damages shall not have
been recovered by Landlord by virtue of payment by Tenant of the Accelerated
Rent Component (but without prejudice to the right of Landlord to demand and
receive the Accelerated Rent Component), such damages shall be payable to
Landlord monthly upon presentation to Tenant of a bill for the amount due.

          (ii) In the event and so long as this Lease shall not have been
terminated after default or breach by Tenant, the rent and all other charges
payable under this Lease shall be reduced by the net proceeds of any
reletting by Landlord (after deducting all costs incident thereto as above
set forth) and by any portion of the Accelerated Rent Component paid by
Tenant to Landlord, and any amount due to Landlord shall be payable monthly
upon presentation to Tenant of a bill for the amount due.

     (e)  In the event Landlord shall, after default or breach by Tenant,
recover the Accelerated Rent Component from Tenant and it shall be determined
at the expiration of the term of this Lease (taken without regard to early
termination for default) that a credit is due Tenant because the net proceeds
of reletting, as aforesaid, plus amounts paid to Landlord by Tenant exceed
the aggregate of rent and other charges accrued in favor of Landlord to the
end of said term, Landlord shall refund such excess to Tenant, without
interest, promptly after such determination.

                                    Page-10

<PAGE>

     (f)  Landlord shall in no event be responsible or liable for any failure
to relet the Demised Premises or any part thereof, or for any failure to
collect any rent due upon a reletting.

     (g)  As an additional and cumulative remedy of Landlord in the event of
termination of this Lease by Landlord following any breach or default by
Tenant, Landlord, at its option, shall be entitled to recover damages for
such breach in an amount equal to the Accelerated Rent Component (determined
from and after the date of Landlord's election under this subsection (g) less
the fair rental value of the Demised Premises for the remainder of the term
of this Lease (taken without regard to the early termination) and such
damages shall be payable by Tenant upon demand. Nothing contained in this
Lease shall limit or prejudice the right of Landlord to prove and obtain as
damages incident to a termination of this Lease, in any bankruptcy
reorganization or other court proceedings, the maximum amount allowed by any
statute or rule of law in effect with such damages are to be proved.

     (h)  In the event of any default occurrence by which Landlord shall have
the rights and remedies specified in this Section 15:

          (i)  Tenant hereby authorizes and empowers any prothonotary or
attorney of any court of record to appear for Tenant and to Confess Judgment
against Tenant (whether by Complaint to Confess Judgment or otherwise) in
favor of Landlord for any amount due to Landlord hereunder (including without
limitation the Accelerated Rent Component), together with interest and costs
and an attorney's commission of five percent (5%) of the amount due; and

          (ii) For the purpose of obtaining possession of the Demised
Premises, Tenant hereby authorizes and empowers any prothonotary or attorney
of any court of record to appear for Tenant and to file in any court an
agreement for entering an amicable action and judgment in ejectment for
recovery of possession, and/or to confess judgment for possession against
Tenant and those claiming by, through or under Tenant in favor of Landlord by
Complaint to Confess Judgment or otherwise, and Tenant agrees that upon such
entry or judgment a writ of possession for the Demised Premises may forthwith
issue.

     (i)  Tenant hereby waives all errors and defect of a procedural nature
in any proceedings brought against it by Landlord under this Lease. Tenant
further waives the right to any notices to quit as may be specified in the
Landlord and Tenant Act of Pennsylvania, as amended, and agrees that five (5)
days' notice shall be sufficient in any case where a longer period may be
statutorily specified.

     (j)  If rent or any other sum due from Tenant to Landlord shall be over
due for more than five (5) days after notice from Landlord, it shall
thereafter bear interest at the rate of twenty percent (20%) per annum (or,
if lower, the highest legal rate) until paid.

                                    Page-11

<PAGE>

     16.  SUBORDINATION. This lease is and shall be subject and subordinate
to all the terms and conditions of all underlying mortgages and to all ground
or underlying leases of the entire Building which may now or hereafter be
secured upon the Building, and to all renewals, modifications,
consolidations, replacements and extensions thereof. This clause shall be
self-operative and no further instrument of subordination, Tenant shall
execute, within fifteen (15) days after request, any certificate that
Landlord may reasonably require acknowledging such subordination.
Notwithstanding the foregoing, the party holding the instrument to which this
Lease is subordinate shall have the right to recognize and preserve this
Lease in the event of any foreclosure sale or possessory action, and in such
case this Lease shall continue in full force and effect at the option of the
party holding the superior lien, and Tenant shall attorn to such party and
shall execute, acknowledge and deliver any instrument that has for its
purpose and effect the confirmation of such attornment.

     17.  NOTICES.  All bills, statements, notices or communications which
Landlord may desire or be required to give to Tenant shall be deemed
sufficiently given or rendered if in writing and either delivered to an
officer of Tenant or sent by registered or certified mail addressed to Tenant
at the Building, and the time of the giving of such notice or communication
shall be deemed to be the time when the same is delivered to Tenant or
deposited in the mail, as the case may be. Any notice by Tenant to Landlord
must be served by registered or certified mail addressed to Landlord at the
address where the last previous rental hereunder was payable, or in the case
of subsequent change upon notice given, to the latest address furnished.

     18.  HOLDING-OVER.  Should Tenant continue to occupy the Demised
Premises after expiration of the term of this Lease or any renewal or
renewals thereof, or after a forfeiture incurred, such tenancy shall (without
limitation of any of Landlord's rights or remedies therefor) be one at
sufferance from month to month at a minimum monthly rental equal to twice the
rent payable for the last month of the term of this Lease.

     19.  MISCELLANEOUS.

          (a)  Tenant represents and warrants that it has not employed any
broker or agent as its representative in the negotiation for or the obtaining
of this Lease, and agrees to indemnify and hold Landlord harmless from any
and all cost or liability for compensation claimed by any broker or agent
with whom it has dealt.

          (b)  The word "Tenant" as used in this Lease shall be construed to
mean tenants in all cases where there is more than one tenant, and the
necessary grammatical changes required to make the provisions hereof apply to
corporations, partnerships or individuals, men or women, shall in all cases
be assumed as though in each case fully expressed. This Lease shall not inure
to the benefit of any assignee, heir , legal representative, transferee or
successor of Tenant except upon the express written consent or election of
Landlord. Subject to the foregoing limitation, each provision hereof shall
extend to and shall, as the case may require, bind and inure to the benefit
of Tenant and its heirs, legal representatives, successors and assigns.

                                    Page-12

<PAGE>

          (c) The term "Landlord" as used in this Lease means the fee owner
of the Building or, if different, the party holding and exercising the right,
as against all others (except space Tenants of the Building) to possession of
the entire Building. Landlord above-named represents that it is the holder of
such rights as of the date of execution hereof. In the event of the voluntary
transfer of such ownership or right to a successor-in-interest of Landlord,
Landlord shall be freed and relieved of all liability and obligation
hereunder which shall thereafter accrue (and, as to any unapplied portion of
Tenant's security deposit, Landlord shall be relieved of all liability
therefor upon transfer of such portion to its successor in interest) and
Tenant shall look solely to such successor in interest for the performance of
the covenants and obligations of the Landlord hereunder (either in terms of
ownership or possessory rights). The successor in interest shall not (i) be
liable for any previous act or omission of a prior landlord; (ii) be subject
to any rental offsets or defenses against a prior landlord; (iii) be bound by
any amendment of this Lease made without its written consent, or by payment
by Tenant of rent in advance in excess of one (i) month's rent; or (iv) be
liable for any security not actually received by it. Subject to the
foregoing, the provisions hereof shall be binding upon and inure to the
benefit of the successors and assigns of Landlord. Notwithstanding anything
to the contrary contained in this Lease, any liability of Landlord, its
agents, partners or employees, arising out of or in respect of this Lease,
the Demised Premises or the Building, and if Landlord shall default in the
performance of Landlord's obligation under this Lease or otherwise Tenant
shall look solely to the equity of Landlord in its interest in the Building.

          (d)  Tenant agrees to execute a memorandum of this Lease in the
form submitted by Landlord, which may be recorded by Landlord. Tenant also
agrees to execute any assignment of this Lease by Landlord, evidencing its
consent to such assignment.

     20.  LANDLORD IMPROVEMENT.  Landlord shall , in a good and workmanlike
manner, cause the Demised Premises to be completed in accordance with the
plans approved by Landlord and Tenant pursuant to Exhibit "A" hereof,
reserving the right to: (a) make substitutions of material of equivalent
grade and quality when and if any specified material shall not be readily and
reasonably available; and (b) make changes necessitated or by conditions met
during the course of construction, provided that Tenant's approval of any
substantial change (and any reduction of cost incident thereto) shall first
be obtained (which approval shall not be reasonably withheld so long as there
shall be general conformity with said working drawings).

     21.  WAIVER OF SUBROGATION.  Each party hereto hereby waives any and
every claim which arises or which may arise in its favor and against the
other party hereto during the term of this Lease, or any extension or renewal
thereof, for any and all loss of; or damage to, any of its property located
within or upon or constituting a part of the Building, to the extent that
such loss or damage is recovered under an insurance policy or policies and to
the extent such policy or policies contain provisions permitting such waivers
of claims. Each party agrees to request its insurers to issue policies
containing such provisions and if any extra premium is payable therefor, the
party which would benefit from the provision shall have the option to pay
such additional premium in order to obtain such benefit.

                                    Page-13

<PAGE>

     22. RENT TAX.  If; during the term of this Lease or any renewal or
extension thereof; any tax is imposed upon the privilege of renting or
occupying the Demised Premises or upon the amount of rentals collected there
for, Tenant will pay each month, as additional rent, a sum equal to such tax
or charge that is imposed for such month, but nothing herein shall be taken
to require Tenant to pay any income, estate, inheritance or franchise tax
imposed upon Landlord.

     23.  PRIOR AGREEMENT, AMENDMENTS.  Neither party hereto has made any
representations or promises except as contained herein or in some further
writing signed by the party making such representation or promise.  No other
agreement hereinafter made shall be effective to change, modify, discharge or
effect an abandonment of this Lease, in whole or in part, unless such
agreement is in writing and signed by the party against whom enforcement of
the change, modification, discharge or abandonment is sought. Tenant agrees
to execute any amendment to this Lease required by a mortgagee of the
Building, which amendment does not materially adversely affect Tenant's
rights or obligation hereunder.

     24.  CAPTIONS.  The captions of the paragraphs in this Lease are
inserted and included solely for convenience and shall not be considered or
given any effect in construing the provisions hereof.

     25.  MECHANIC'S LIEN. Tenant shall, within ten (10) days after notice
from Landlord, discharge any mechanic's lien for materials or labor claimed
to have been furnished to the Demised Premises on Tenant's behalf (except for
work contracted for by Landlord) and shall indemnify and hold harmless
Landlord from any loss incurred in connection therewith.

     26.  LANDLORD'S RIGHT TO CURE. Landlord may (but shall not be
obligated), on five (5) days notice to Tenant (except that no notice need be
given in case of emergency) cure on behalf of Tenant any default hereunder by
Tenant, and the cost of such cure (including any attorney's fees incurred)
shall be deemed additional rent payable upon demand.

     27.  PUBLIC LIABILITY INSURANCE. Tenant shall at all times during the
term hereof maintain in full force and effect with respect to the Demised
Premises and Tenants use thereof; comprehensive public liability insurance,
naming Landlord as an additional insured, covering injury to person in
amounts at least equal to One Million ($1,000,000) Dollars combined single
limit bodily injury and property. Tenant shall lodge with Landlord duplicate
originals or certificates of such insurance at or prior to the commencement
date of the term hereof; together with evidence of paid-up premiums, and
shall lodge with Landlord renewals thereof at least fifteen (15) days prior
to expiration.

                                    Page-14

<PAGE>

     28.  ESTOPPEL STATEMENT.  Tenant shall from time to time, within ten
(10) days after request by Landlord, execute, acknowledge and deliver to
Landlord a statement certifying that this Lease is unmodified and in full
force and effect (or that the same is in full force and effect as modified,
listing any instruments or modifications), the dates to which rent and other
charges have been paid, and whether or not, to the best of Tenant's
knowledge, Landlord is in default or whether Tenant has any claims or demands
against Landlord (and, if so, the default, claim and/or demand shall be
specified).

     29.  RELOCATION OF TENANT.  Landlord, at its sole expense, on at least
sixty (60) days prior written notice, may require Tenant to move from the
Demised Premises to another suite of comparable size and decor in order to
permit landlord to consolidate the Premises with other adjoining space leased
or to he leased to another tenant in or coming into the Building. In the
event of any such relocation, Landlord will pay all the expenses of preparing
and decorating the new premises so that they will be substantially similar to
the premises and the expense of moving Tenant's furniture and equipment to
the relocated premises. Occupancy of the new Premises shall be under and
pursuant to the terms of this lease. Tenant will have right of first offer to
lease contiguous space after initial lease-up of such space.

     30.  TENANT'S APPROVAL.  Prior to installation, Tenant shall have the
right to inspect the following items that are included as Tenant
Improvements:

          1.  All telephone and data cable within the Demised Premises (to meet
              specifications provided by Tenant).
          2.  All pinouts to be used on end connectors prior to being punched
              down within the Demised Premises (to meet specifications provided
              by Tenant).
          3.  All lighting fixtures within the Demised Premises

     IN WITNESS WHEREOF, the parties hereto have executed this Lease or
caused this Lease to be executed by their duly authorized representatives the
day and year first above written.

                                       LANDLORD: BALDWIN TOWERS ASSOCIATES, L.P.

                                       BY:  /s/  [illegible]
                                          -------------------------------------

                                       DATE:  4/3/95
                                             --------

                                       TENANT:   NEPTUNE SYSTEMS, INC.

                                       BY:  /s/  [illegible]
                                          -------------------------------------

                                       DATE:  4/3/95
                                             --------

                                    Page-15

<PAGE>

                                 SCHEDULE "A"

                                  RENT RIDER

<TABLE>
<CAPTION>

     PERIOD               ANNUALLY           MONTHLY        PER SQ.FT.
     ------               --------           -------        ----------
<S>                      <C>                <C>             <C>
7/1/95 - 6/30/96         $59,026.00          $4,18.33         $11.00
7/1/96 - 6/30/00         $80,490.00         $6,707.50         $15.00
7/1/00 - 6/30/05         $85,856.00         $7,154.67         $16.00

</TABLE>

                                    Page-16

<PAGE>

                                     EXHIBIT "C"

                            BUILDING RULES AND REGULATIONS

     1.   The sidewalks, entryways, passages, corridors, stairways and elevators
shall not be obstructed by any of the tenants, their employees or agents, or
used by them for purposes other than ingress or egress to and from their
respective suites. All safes or other heavy articles shall be carried up or into
the leased premises only at such times and in such manner as shall be prescribed
by the Landlord and the Landlord shall in all cases have the right to specify a
maximum weight and proper position or location of any such safe or other heavy
article. Any damage done to the Building by taking in or removing any safe or
from overloading any floor in any way shall be paid by the Tenant. The cost of
repairing or restoring any part of the Building which shall be defaced or
injured by a tenant, its agents or employees, shall be paid for by the Tenant.

     2.   Each Tenant will refer all contractors, contractors representatives
and installation techniques rendering any service on or to the leased premises
for the tenant to Landlord for Landlord's approval and supervision before
permanence of any contractual service. This provision shall apply to all work
performed in the Building, including installation of telephones, telegraph
equipment, electrical devices and attachments and installations of any nature
affecting floors, walls, woodwork, trim, windows, ceilings, equipment or any
other physical portion of the Building.

     3.   No, sign, advertisement or notice shall be inscribed, painted or
affixed on any part of the inside or outside of the Building unless of such
color, size and style and in such place upon or in the Building as shall first
be designated by Landlord; there shall be no obligation or duty on Landlord to
allow any sign, , advertisement or notice to be inscribed, painted or affixed on
any part of the inside or outside of the Building except as specified in a
tenant's lease. Signs on or adjacent to doors shall be in color, size and style
approved by Landlord, the cost to be paid by the tenants.  A directory in a
conspicuous place, with the names of tenants, will be provided by Landlord; any
necessary revision in this will be made by Landlord within a reasonable time
after notice from the tenant of an error or of a change making revision
necessary. No furniture shall be placed in front of the Building or in any lobby
or corridor without written consent of Landlord.

     4.   No tenant shall do or permit anything to be done in its leased
premises, or bring to keep anything therein, which will in any way increase the
rate of fire insurance on the Building, or on property kept therein, or obstruct
or interfere with the rights of other tenants, or in any way injure or annoy
them, or conflict with the laws relating to fire prevention and safety, or with
any regulations of the fire department, or with any rules or ordinances of any
Board of Health or other governing bodies having jurisdiction over the Building.

     5.   The janitor of the Building may at all times keep a pass-key, and he
and other agents of the Landlord shall at all times, be allowed admittance to
the leased premises for purposes permitted in Tenant's lease.

Initial [ILLEGIBLE]
       ---------------
        [ILLEGIBLE]
       ---------------

                                Page-17
<PAGE>

     6.   No additional locks shall be placed upon any doors without the written
consent of the Landlord. All necessary keys shall be furnished by the Landlord,
and the same shall be surrendered upon the termination of this Lease, and the
Tenant shall then give the Landlord or his agents explanation of the combination
of all locks upon the doors of vaults.

     7.   The water closets and other water fixtures shall not be used for any
purpose other than those for which they were constructed, and any damage
resulting to them from misuse or abuse by a tenant or its agents, employees or
invitees, shall be borne by the Tenant.

     8.   No person shall disturb the occupants of the Building by the use of
any musical instruments, the making or transmittal of noises which are audible
outside the leased premises, or any unreasonable use. No dogs or other animals
or pets of any kind will be allowed in the Building.

     9.   No bicycles or similar vehicles will be allowed in the building.

     10.  Nothing shall be thrown out the windows of the building or down the
stairways or other passages.

     11.  Tenants shall not be permitted to use or to keep in the Building any
kerosene, camphene, burning fluid or other illuminating materials.

     12.  If any tenant desires telegraphic, telephonic or other electric
connections, Landlord or its agents will direct the electricians as to what and
how the wires may be introduced, and without such directions no boring or
cutting for wires will be permitted.

     13.  If a tenant desires shades, they must be of such shape, color,
materials and make as shall be prescribed by Landlord. No outside awning shall
be permitted.

     14.  No portion of the Building shall be used for the purposes of lodging
rooms or for any immoral or unlawful purposes.

     15.  No tenant shall store anything outside the building or in any common
areas in the building.

Initial [ILLEGIBLE]
       ---------------
        [ILLEGIBLE]
       ---------------

                                  Page-18
<PAGE>

                                   [MAP]

<PAGE>

                                LEASE AMENDMENT

--------------------------------------------------------------------------------
--------------------------------------------------------------------------------

This Agreement dated JULY 6, 1995 to be made part of a certain Lease dated
APRIL 3, 1995 between BALDWIN OFFICE ASSOCIATES, L.P. (henceforth called
"Landlord") and NEPTUNE SOFTWARE (henceforth called "Tenant") for OFFICE
space in the BALDWIN TOWERS OFFICE BUILDING, EDDYSTONE, PENNSYLVANIA as more
particularly described below:

1.   The Commencement Date noted in Section 1 of the Lease shall change to
     September 1, 1995 or later by XXXXXXXXXXXX three weeks prior written notice
     to Tenant.

2.   Schedule "A" of the Lease shall change to the following:

<TABLE>
<CAPTION>

          PERIOD         MONTHLY        ANNUALLY            PER SQ. FT.
          ------         -------        --------            -----------
     <S>                 <C>            <C>                 <C>
     Months 01-04          $0             $0                    $0
     Months 05-12        $4,918.83      $59,026.00            $11.00
     Months 13-60        $6,707.50      $80,490.00            $15.00
     Months 61-120       $7,154.67      $85,856.00            $16.00

</TABLE>

3.   Upon Tenant occupancy, Landlord shall issue a payment to Tenant of
     $5,000.00 as additional XXXXXXXXX.

4.   The XX sentence of Section 10. DELAY IN POSSESSION, noted with an
     asterisk, becomes void and unenforceable.

5.   All other terms and conditions of the Lease shall remain in full force and
     effect.

6.   Provided Tenant is XXX in Default of any of the terms or conditions of this
     Lease XXXXXXXX this Lease on the date of the sixth anniversary of the
     Commencement Date by XXXXXXXXXXXXXX months' prior written notice of such
     intention and delivering a fee (the XXXXXXXXXXX eight months rent plus all
     Landlord's costs associated with the lease transaction XXXXXXXXX to be
     amortized over the remaining Lease Term assuming an interest rate of twelve
     percent (12%).

7.   Landlord shall be known as Baldwin Office Associates, L.P.

AGREED AND ACCEPTED

/s/ [illegible]
-----------------------------------     -----------------------------------
NEPTUNE SOFTWARE                        BALDWIN OFFICE ASSOCIATES, L.P.

DATE:   7/6/95                          DATE:

<PAGE>

                              AMENDMENT TO LEASE

THIS AMENDMENT TO LEASE ("AMENDMENT") is made this 17th day of June, 1996
between BALDWIN OFFICE ASSOCIATES, L.P. ("LANDLORD") and NEPTUNE SYSTEMS,
INC. ("TENANT").

                                 BACKGROUND

     A.  Landlord and Tenant are parties to that certain Lease dated April 3,
1995 (the "Lease"), pursuant to which Landlord leased to Tenant approximately
5,366 square feet of space (the "Original Leased Premises") on the sixth
(6th) floor of the building ("Building") known as Baldwin Tower located at
1510 Chester Pike, Eddystone, Pennsylvania.

     B.  The parties desire to relocate the premises leased to Tenant under the
Lease from the sixth (6th) floor to the third (3rd) floor and to increase the
total leased square footage to thirteen thousand nine hundred eighty (13,980)
rentable square feet (the "New Demised Premises").

     C.  The parties desire to amend the Lease to provide for the New Demised
Premises and to make certain other amendments to the Lease as provided herein.

     NOW, THEREFORE, in consideration of the mutual covenants contained herein,
the parties hereto, intending to be legally bound, hereby agree as follows:

1.   The Demised Premises defined in Section 1 of the Lease changes to the New
     Demised Premises containing 13,980 rentable square feet located on the
     third floor of the Building, known as suite 640.

2.   The Term defined in Section 2 of the Lease shall be ten (10) years and
     nine days commencing on July 22, 1996 and ending on July 31, 2006.

3.   The Schedule "A" Rent Rider to the Lease changes to the following:

<TABLE>
                  PERIOD                   MONTHLY        ANNUALLY
<S>                                       <C>            <C>
       July 15, 1996 - July 31, 1997      $15,757.50     $189,090.00
       August 1, 1997 - July 31, 2001     $19,222.50     $230,670.00
       August 1, 2001 - July 31, 2006     $20,387.50     $244,650.00
</TABLE>

4.   Tenant's fraction defined in Section 4(a)(iii) of the Lease changes to
     13,980/166,250 (i.e. 8.41%).

5.   Landlord shall improve the New Demised Premises according to the plan
     drawn by T. E. Hall Architects dated May 28, 1996, Revision #2, a copy
     of which Plan is attached hereto as EXHIBIT "A" and made a part hereof.
     The cost of improving the New Demised Premises (the "Relocation Cost")
     which includes a contribution for office furniture of $27,995.20, a
     moving allowance of $5,000.00 and an improvement allowance of $15.00 per
     rentable square foot ($209,000.00) shall be borne by the Landlord. In
     the event that the actual Relocation Cost is greater than $242,695.50
     but less than $271,303.00, the portion which is greater than $242,695.50
     will be paid 50% by the Landlord and 50% by the Tenant. In the event the
     actual Relocation Cost is greater than $271,303.00, the portion which is
     greater than $271,303.00 will be paid entirely by the Tenant.

6.   Tenant shall be notified and offered any space in the Buiding which
     becomes available on the second, third or fourth floor of the Building
     prior to such space being leased to a third party. However, Tenant shall
     not have a right of first refusal with regard to such space.

<PAGE>

                                  SCHEDULE "A"

                                   RENT RIDER

     PERIOD                ANNUALLY             MONTHLY         PER SQ. FT.
----------------          ----------           ---------        -----------
7/1/95 - 6/30/96          $59,026.00           $4,918.33          $11.00
7/1/96 - 6/30/00          $80,490.00           $6,707.50          $15.00
7/1/00 - 6/30/05          $85,856.00           $7,154.67          $16.00

                                      Page-16
<PAGE>

                           THIRD AMENDMENT TO LEASE

-------------------------------------------------------------------------------

THIS THIRD AMENDMENT TO LEASE ("THIRD AMENDMENT") is made this 26th day of
June, 1996 between BALDWIN OFFICE ASSOCIATES, L.P. ("LANDLORD") and NEPTUNE
SYSTEMS, INC. ("TENANT").

                                     BACKGROUND

A.   Landlord and Tenant are parties to that certain Lease ("LEASE") dated April
     3, 1995, pursuant to which Landlord leased to Tenant approximately 5,366
     square feet of space (the "ORIGINAL LEASED PREMISES") on the sixth floor of
     the building ("BUILDING") known as Baldwin Tower located at 1510 Chester
     Pike, Eddystone, Pennsylvania. The Lease was amended pursuant to that
     certain Lease Amendment dated July 6, 1995 (the "FIRST AMENDMENT") and was
     further amended pursuant to that certain Amendment to Lease dated June 17,
     1996 (the "SECOND AMENDMENT").

B.   The Second Amendment expanded and relocated the Demised Premises to 13,980
     square feet on the third floor of the Building which was referred to as the
     "NEW DEMISED PREMISES", and the Tenant relinquished its rights in the
     Original Leased Premises.

C.   The Tenant desires to include the Original Leased Premises with the New
     Demised Premises as part of Tenant's leasehold interest under the Lease.

D.   The parties desire to amend the Lease to provide for the inclusion of the
     Original Leased Premises and to make certain other amendments to the Lease
     as provided herein.

          NOW, THEREFORE, in consideration of the mutual covenants contained
herein, the parties hereto, intending to be legally bound, hereby agree as
follows:

1.   The Demised Premises under the Lease shall include the Original Leased
     Premises and the New Demised Premises totaling 19,346 rentable square feet.

2.   The Schedule "A" Rent Rider to the Lease changes to the following:

<TABLE>
<CAPTION>

              PERIOD                       MONTHLY        ANNUALLY
              ------                       -------        --------
    <S>                                  <C>            <C>
    July 15, 1996 - September 15, 1996   $15,757.50     $189,090.00
    September 16, 1996 - July 31, 1997   $22,465.00     $269,580.00
    August 1, 1997 - July 31, 2001       $25,930.00     $311,160.00
    August 1, 2001 - July 31, 2006       $27,542.17     $330,506.04
</TABLE>
<PAGE>

3.   Tenant's Fraction defined in Section 4 of the Lease changes to
     19,346/166,250 (i.e. 11.6%).

4.   The first sentence of Paragraph 5 of the Second Amendment is deleted.
     Tenant shall select its own architect to design the New Demised Premises
     ("TENANT'S ARCHITECT'S DESIGN"). The Relocation Cost shall be allocated as
     specified in the Second Amendment. Provided that Landlord approves of
     Tenant's Architect's Design, in Landlord's sole and absolute discretion,
     Landlord shall complete the improvement of the New Demised Premises in
     accordance with Tenant's Architect's Design within sixty (60) days of such
     approval. In the event Landlord disapproves of Tenant's Architect's Design,
     Landlord shall deliver the sum of $257,695.20 to be paid as the
     construction is completed to Tenant, and Tenant shall complete the
     improvement of the New Demised Premises in accordance with Tenant's
     Architect's Design at Tenant's sole cost and expense within sixty (60) days
     of such disapproval. The cost of architectural services associated with the
     Tenant's Architect's Design shall be included as part of the Relocation
     Cost.

5.   Section 8 of the Second Amendment is deleted.

6.   The terms and conditions of the Lease as modified hereby shall remain in
     full force and effect and are hereby ratified, confirmed, and reaffirmed
     for all purposes and in all respects. All capitalized words not otherwise
     defined herein shall have the meanings as defined in the Lease, the First
     Amendment or the Second Amendment.

AGREED AND ACCEPTED

/s/ [illegible]                         /s/ [illegible]
-----------------------------------     -----------------------------------
NEPTUNE SYSTEMS, INC.                   BALDWIN OFFICE ASSOCIATES, L.P.

DATE:   6/25/96                          DATE: 6/26/96

<PAGE>

                        EXPANSION, EXTENSION & RELOCATION
                                    AMENDMENT
-------------------------------------------------------------------------------

This Amendment dated ___________ to be made part of a certain Lease
("Lease")dated APRIL 3, 1995 between BALDWIN OFFICE ASSOCIATES, L.P. (henceforth
called "Landlord") and NEPTUNE SOFTWARE (henceforth called "Tenant") for OFFICE
space in the BALDWIN TOWER OFFICE BUILDING, EDDYSTONE, PENNSYLVANIA as more
particularly described below:

1.   The Demised Premises defined in Section 1 of the Lease changes to 13,980
     rentable square feet on the third floor of the Building, known as suite
     640.

2.   The Term defined in Section 2 of the Lease shall be ten (10) years and two
     (2) weeks commencing on July 15, 1996 and ending on July 31, 2006.

3.   Schedule "A" Rent Rider changes to the following:

<TABLE>
                  PERIOD                   MONTHLY         ANNUALLY
<S>                                       <C>            <C>
       July 15, 1996 - July 31, 1997      $15,757.50     $189,090.00
       August 1, 1997 - July 31, 2001     $19,222.50     $230,670.00
       August 1, 2001 - July 31, 2006     $20,387.50     $244,650.00
</TABLE>

4.   Tenant's fraction defined in Section 4(a)(iii) changes to 13,980/166,250
     (i.e. 8.41%)

5.   Landlord shall improve the Demised Premises according to the attached plan
     drawn by T. E. Hall Architects dated May 28, 1996, Revision #2. The cost of
     such buildout which includes a contribution for office furniture of
     $27,995.20, a moving allowance of $5,000.00 and an improvement allowance of
     $15.00 per rentable square foot ($209,000.00) shall be borne by the
     Landlord.

     In the event that the actual costs for improvements are greater than
     $242,695.50 but less than $271,303.00, the portion which is greater than
     $242,695.50 will be paid 50% by the Landlord and 50% by the Tenant. In the
     event the actual costs for improvements is greater than $271,303.00, the
     portion which is greater than this amount will be paid entirely by the
     Tenant.

6.   Tenant shall be notified of any unit which becomes available on the second,
     third or fourth floor of the Building - prior to such space being leased to
     a third party. However, Tenant shall not have a right of first refusal with
     regard to such space.

<PAGE>

7.   Provided that Tenant is not in default of any of the terms or conditions of
     the Lease; as amended hereby, and Landlord is unable to provide additional
     square footage in the Building sufficient to accommodate the reasonable
     expansion needs of Tenant, Tenant may buy out of this Lease by providing
     one year's prior written notice to Landlord, of Tenant's intention to
     terminate the Lease and paying, at the time of such notice, an amount equal
     to:

          A.   The cost of improvements, commissions, and free rent period
               associated with this Amendment that will remain unamortized
               over the balance of the lease term assuming an interest rate
               of ten percent (10%) at the time of the notice; plus

          B.   A Lease Cancellation Payment in accordance with the following
               schedule:

<TABLE>
          LEASE YEAR DURING WHICH NOTICE IS GIVEN      PAYMENT AMOUNT
          <S>                                          <C>
                         1                             2 1/2 yrs. rent
                         2                             2 1/4 yrs. rent
                         3                                2 years rent
                         4                             1 3/4 yrs. rent
                         5                             1 1/2 yrs. rent
                         6                             1 1/4 yrs. rent
                         7                                1 years rent
                         8                              3/4 years rent
                         9                              1/2 years rent
                         10                               0 years rent
</TABLE>

8.   Upon Tenant's relocation to the third floor, all partition furniture in the
     sixth floor space will become the property of the Landlord.

9.   All other terms and conditions of the Lease shall remain in full force and
     effect.

AGREED AND ACCEPTED

--------------------------    ------------------------------
NEPTUNE SOFTWARE              BALDWIN OFFICE ASSOCIATES, L.P.
Date:     /    /              Date:     /    /

<PAGE>

                                 BALDWIN OFFICE, INC.

                                     SUBCONTRACT

     THIS SUBCONTRACT ("Subcontract") is made the day of    , 1995, by
             (hereinafter) referred to as the ("Subcontractor") and BALDWIN
OFFICE, INC. (hereinafter referred to as the ("Contractor").

     The subcontractor and the Contractor, in consideration of the mutual
promises contained herein, and intending to be legally bound hereby, agree as
follows:

     1.   THE SUBCONTRACT WORK.

          A.   The Subcontractor shall furnish all labor and material for
equipment for, and perform all services necessary to complete the Subcontract
Work (as hereinafter described) in connection with the rehabilitation of the
existing Baldwin Towers general office building located in the Borough of
Eddystone, Delaware County, Pennsylvania (hereinafter referred to as the
"Project").  The Subcontract Work shall be performed in accordance with the
Construction Agreement between Baldwin Office, Inc.(hereinafter referred to as
the "Owner") and the Contractor, the exhibits thereto, drawings, plans
specifications and other contract documents referred to therein and dated the
January 22, 1991, all of which documents are hereinafter referred to as the
"Principal Contract" and are incorporated herein by reference. The Subcontract
Work shall consist of the items listed on Exhibit "A" attached hereto.

          B.   The Subcontractor acknowledges that he has completely reviewed
all drawings, specifications, addenda and other contact documents with regard to
the Project and is satisfied that it can complete all Subcontract Work in
accordance with this Subcontract and the Principal Contract.

          C.   The Subcontractor shall perform the Subcontract Work in strict
accordance with the Principal Contract as it relates to the Subcontract Work and
assumes all the responsibilities and obligations which the Contractor, by the
Principal Contract, has assumed and agreed to perform for the Owner.  Any work
not specifically referred to in this Subcontract but which may be reasonably
inferred therefrom shall also be performed and completed when and as required by
the Subcontractor. To the extent that the Principal Contract imposes standards
that are stricter than those in this Subcontract, the provisions of the
Principal Contract shall be given effect.

          D.   The Subcontractor acknowledges that it has taken steps reasonably
necessary to ascertain the nature and location of the Subcontract Work, and that
it has investigated and satisfied itself as to the general and local conditions
which can effect the Subcontract Work or its cost, including but not limited to
(1) conditions bearing upon transportation, disposal, handling, and storage of
materials; (2) the availability of labor, water, electric power, and roads; (3)
uncertainties of weather; (4) the confirmation of conditions of the ground; and
(5) the character of equipment and facilities needed preliminary to and during
performance.  The Subcontractor also acknowledges that it has satisfied itself
as to the character, quality, and quantity of surface and subsurface materials
or obstacles and assumes all responsibilities for all such conditions. Any
failure of the Subcontractor to take the actions described and acknowledged in
this paragraph will not relieve the Subcontractor from responsibility for
estimating properly the difficult and cost of successfully performing the
Subcontract Work, or for proceeding to successfully perform the Subcontract Work
without additional expense to the Subcontractor.  The Contractor assumes no
responsibility for any conclusions or interpretations made the Subcontractor
based on the information made available by the Contractor, any engineer or
Owner. Nor does the Contractor assume the Subcontract Work by any of its
officers or agents before the execution of this Subcontract, unless that
understanding or representation is expressly stated in this subcontract.

<PAGE>

          E.   The contractor may at any time issue written orders requiring
alterations or additions to the Subcontract Work.  The Subcontractor shall not
alter or perform additions to the Subcontract Work except upon receipt of such
written orders.

     2.   TIME OF PERFORMANCE

          A.   Time being of the essence hereunder, the Subcontractor shall
begin, prosecute, and complete the Subcontract Work at the times required by the
Contractor.

          B.   If the Subcontractor shall be delayed in beginning, prosecuting
or completing the Subcontract Work by the act, omission, neglect or default of
the Contractor, the Owner, or any contractor subcontractor performing work upon
the Project, or by any damage caused by fire or other casualty for which the
Subcontractor is not responsible, the time of the completion of the Subcontract
Work shall be extended for such period of time as the time lost by reason of any
of the aforesaid causes.  Such an extension shall be the Subcontractor's sole
and exclusive remedy for such delay and the Contractor shall not be responsible
for any increased costs, charges, expenses or damages of any kind resulting from
such delay.

          C.   No allowance of an extension of the time for performance of the
Subcontract Work will be granted, unless a claim therefore is presented to the
Contractor in writing within forty-eight hours of the occurrence of the cause
hereof.

          D.   If the contractor shall at any time be behind in the Subcontract
Work, or if in the opinion of the Contractor, the Subcontractor is delaying the
progress of the work necessary to complete the Project, then and in either such
event, if requested by the Contractor, the Subcontractor, at its sole cost and
expense, shall perform such overtime work as may be necessary to keep abreast
with the general progress of the work at the Project, and/or to complete the
Subcontract Work at the time required by the Contractor and Subcontractor is set
forth on Exhibit "A" together with the description of the Subcontract Work.

   3.     PAYMENT

          A.   The space Contractor shall pay the Subcontractor for the
performance of the Subcontract Work the Sum of
($           )(hereinafter referred to as the "Subcontract Price"), subject
to such additions and deductions for alterations or additions to the
Subcontract Work as may be ordered by the Contractor. The Subcontract Price
shall be paid to the Subcontractor as hereinafter provided.

          B.   Before beginning the Subcontract Work, the Subcontract shall
prepare and submit to the Contractor for approval an itemized breakdown of the
Subcontract Price, allocating amounts thereof to the several items of work and
material of the Subcontract Work conforming to the breakdown of items designated
by the Contractor, which itemized breakdown, upon approval by the Contractor,
shall be used as the basis for all requisitions for payment submitted by the
Subcontractor to the Contractor.

          C.   The Subcontractor, unless otherwise directed by the Contractor,
shall submit to the Contractor on or about the tenth (10th) day of each calendar
month a requisition containing an itemized estimate of the Subcontract Work done
and materials furnished and incorporated into the Project during the recent
calendar month which shall be in such form and be supported by such information,
certificates and documents as the contractor shall require.  The amount to which
the Subcontractor shall be entitled upon any such monthly requisition shall be
the amount approved by the Owner's construction lender.

                                      2
<PAGE>

          D.   It is the intent of the Contractor and the Subcontract that:
(1) payments to the Subcontractor shall be made from a fund, the sole source
of which shall be funds paid by the Owner to the Contractor, and (2) the risk
of the Owner's insolvency and/or failure to make such payments shall be borne
by the Subcontractor. With the foregoing in mind, the Contractor and
Subcontractor agree that the Contractor shall pay to the Subcontractor within
five (5) days after receipt of the corresponding payment from the Owner,
ninety percent (90%) of the amount approved by the Owner's construction
lender.

          E.   The balance due or final payment to the Subcontractor shall be
paid by the Contractor to the Subcontractor within five (5) days after receipt
of final payment from the Owner for the Subcontract Work. Before issuance of the
final payment, the Subcontractor shall submit evidence satisfactory to the
Contractor that all payrolls, bills for materials and equipment, and all known
indebtedness connected with the Subcontractor's Work have been satisfied.

          F.   The Subcontractor agrees to and does hereby accept full and
exclusive liability for the payment of any and all contributions, taxes or
insurance of any description whatsoever, now or hereafter imposed by any
authority, which are measured by the wages, salaries or other remuneration's
paid to persons employed by the Subcontractor on work performed pursuant to the
terms of this Subcontract. Furthermore, the Subcontractor agrees to and does
hereby accept full and exclusive liability for payment of any all personal
property taxes, inventory taxes, sales taxes, use taxes, excise taxes, fuel
taxes, transportation taxes, franchise taxes, and all other taxes and/or tax
assessments in any manner whatsoever relating to the materials, supplies, tools,
machinery, equipment and plant which may be purchased, acquired, rented or used
by Subcontractor relating to all work performed under this Subcontract as is or
may be imposed or assessed by any Federal, State, Local, or other political
subdivision or agency. Notwithstanding the foregoing, the Contractor shall have
the right, but not the obligation to pay directly to anyone performing any part
of the Subcontract Work any amount due for labor, materials, equipment or
services supplied in connection with the performance of the Subcontract Work. In
such event, the Contractor shall also have the right but not the obligation to
pay directly to any tax authority or agency any tax or other payment or charge
which the Contractor would have been required to pay or to have withheld and
pay. All such payments made by the Contractor shall be credited against the
payment then due the Subcontractor. This provision is not intended to and shall
not create any third party beneficiary rights in any third party nor shall it
impose any obligation upon the Contractor to supervise payments due by the
Subcontractor to any of its subcontractors, materialmen, laborers, suppliers or
taxing authorities.

          G.   The Contractor may deduct from amounts due or to become due to
the Subcontractor, any sums due or to become due to the Contractor from the
Subcontractor whether or not said sums are in any way related to this
Subcontract or Project. Contractor may apply such deducted funds to any account
related or unrelated to this Subcontract or Project, wherein the obligations of
the Subcontractor have not been discharged and wherein the Contractor's
interests are directly or indirectly involved.

               If the Subcontractor is in default of, or breaches or fails to
comply with any provision, covenant or requirement of this Subcontract; or
any person assets, or indicates that he will assert, any lien, claim, demand
or charge against the Project or land or improvements or funds related to the
Project, or against the Owner or the Contractor, arising from Subcontractor's
performance of this Subcontract, the Contractor may, at this option, withhold
out of any payments due or to become due to the Subcontractor such amounts as
the Contractor, in its sole discretion, may deem sufficient to completely
protect and indemnify the Contractor and the Owner from any and all loss,
damage and/or expense therefore, including attorney's fees and litigation
costs, until the condition requiring such measures has been remedied by the
Subcontractor.  If the offending condition is not remedied by the
Subcontractor within a reasonable period of time, the Contractor may, in its
discretion, determine as being in the best interest of itself and/or the
Owner.  If the Contractor is compelled to expend monies in defending,
discharging or otherwise disposing of any claim or lien or other demand in
excess of retained or withheld sums, the Subcontractor shall, upon demand,
reimburse the Contractor for the excess amount so expended, including
reasonable attorney fees and costs incurred by Contractor incident to such
defense, discharge or disposition and/or incident to Contractor's collection
from Subcontractor of such excess.

                                     3
<PAGE>

          H.   Payments made hereunder shall not be evidence of the acceptance
of performance of this Subcontract, either wholly or in part, and no payment
shall be construed to be an acceptance of the Subcontract Work, or any part
thereof. Acceptance by the Subcontractor of the final payment hereunder shall be
deemed to be a complete and unconditional release of any and all existing or
future claims or demands by the Subcontractor against the Contractor, known or
unknown, hereunder or in connection herewith, whatever they may be or howsoever
they may arise, as well as for every action and neglect of the Contractor and
any person or firm for whom the Contractor shall or may be deemed responsible.

          I.   The Subcontract Price includes all federal, state, municipal and
local taxes including but not limited to sales and or use taxes applicable to
the performance of the Subcontract Work.

     4.   INSURANCE

     A.   The Subcontractor, before beginning the Subcontract Work, shall
procure from such insurance company or companies and/or its or their affiliated
companies as may be approved by the Contractor, policies with such limits of
liability as the Contractor shall deem necessary to protect the Contractor from
claims under Workmen's Compensation, Public Liability, Property Damage, and such
other insurance or coverage as required by the Contractor or the Principal
Contract, including without limitation claims for damages for personal injury,
including death, which may arise from operations under this Subcontract carried
on either by the Subcontractor or by any of its subcontractors.  The
Subcontractor shall, by making all payments of the premiums due thereon,
maintain said insurance policies in full force and effect until such time as all
the Subcontract Work shall have been entirely completely and accepted in
accordance with the Principal Contract.  Certificates evidencing that such
required insurance is in with the Principal Contract.  Certificates evidencing
that such required insurance is in effect shall be furnished by the
Subcontractor to the Contractor promptly after such insurance has been procured.
Such certificates shall not be altered, amended or terminated until the
insurance company which has issued said policy has given the Contractor notice
thereof and thirty (30) days have elapsed from the date of Contractor's receipt
of said notice.

          B.   In case of the failure of the Subcontractor to provide or
maintain such insurance and policies in full force and effect as aforesaid,
the Subcontractor hereby authorizes the Contractor, without any notice of its
intention to do so, to provide such required policies of insurance and other
coverage, on behalf for the account of the Subcontractor and to pay any and
all premiums due thereon, and to deduct the aggregate amount of such premiums
so paid by the Contractor from any monies, which may be due or thereafter
become due to the Subcontractor under this Subcontract.

          C.   This Subcontractor, by compliance with the foregoing requirements
as to insurance, shall not be relieved from any liability whatsoever imposed by
the provisions of this Subcontract, the Principal Contract or otherwise.

     5.   INDEMNIFICATIONS.

          A.   The Subcontractor hereby agrees to indemnify and hold harmless
the Contractor and its officer's directors, agents, representatives, employees,
successors and assigns from and against any and all claims, loss, damage, costs,
suits, actions, causes of action, expenses and liability of any kind which it or
any of them may incur, suffer, sustain or be required to pay by reason of the
injury or death of any person or the damage to any property whatsoever, caused
or alleged to have been caused by any act or omission of the Subcontractor or
any of its suppliers or subcontractors, or the employees, agents or
representatives of the Subcontractor or any of its suppliers or subcontractors,
arising out of, or in any manner connected with the performance of the
Subcontract Work.

          B.   The Subcontractor agrees to indemnify and hold harmless the
Contractor from and against any and all actions, suits, proceedings, claims
or demands arising out of, or alleged to have arisen out of the performance
of, or the operations under this Subcontract. If any action, suit or
proceeding is instituted against

                                     4

<PAGE>

the Contractor based upon any liability or defect arising out of or alleged
to have risen out of the performance or the operations under this Subcontract,
the Contractor shall, within thirty (30) days, give notice in writing thereof
to the Subcontractor.  Upon the receipt of such notice, the Subcontractor, at
its own cost and expense, shall defend against such action, suit proceeding,
claim, counterclaim, set-off, recoupment or other defense and take all such
steps as the Contractor may deem necessary to prevent the obtaining of
Judgment against or the successful maintenance of such claim, counterclaim,
set-off, recoupment or other defense against the Contractor. Notwithstanding
the foregoing, the Contractor shall be permitted to be represented by its own
counsel should Contractor so desire.

          C.   If any action, suit, proceeding, claim or demand is made against
the Contractor, its officers, directors, agents, representatives, employees,
successors or assigns against which the Subcontractor has herein agreed to
indemnify the Contractor, then the Contractor may withhold from any payment due
or hereafter to become due to the Subcontractor hereunder, an amount sufficient
in its sole judgment to protect and indemnify it from such action, suit,
proceeding, claim or demand, together with legal fees ad disbursements.

     6.   ADDITIONAL OBLIGATIONS OF THE SUBCONTRACTOR

          A.   The Subcontractor shall:

          (1)  provide and supply, in the performance of the Subcontract Work
a sufficient number of properly skilled and other workmen and whatever
material, tools, equipment, machines, services, storage sheds, workshops,
offices, other temporary structures and other facilities which shall be
necessary to the performance of the Subcontract Work.  The Subcontractor
agrees that the Contractor's equipment shall be available to the
Subcontractor only at the Contractor's discretion and on mutually agreeable
terms. All equipment, materials and articles incorporated in the Subcontract
Work shall be new and of the most suitable grade for the purpose intended,
otherwise specifically provided in this Subcontract or the contract documents
for the Project. References in the contract, documents for the Project to
equipment, material, articles, or patented processes by trade, make, or
catalog number shall be regarded as establishing a standard of quality. The
Subcontractor at its option, may use any equipment, material, article or
process that, in the sole judgment of the Contractor, is equal to that named
in the Specifications provided in the Principal Contract.  The Contractor may
withhold such approval for any reason.

          (2)  obtain the Contractor's approval of the machinery and mechanical
and other equipment to be incorporated into the Subcontract Work. Machinery,
equipment, material and articles that are not approved shall be installed or
used at the risk of subsequent rejection.

          (3)  give all notices and comply with all laws, ordinances, rules and
regulations and orders of any public authority bearing on the performance of the
Subcontract Work. The Subcontractor shall secure and pay for permits and
governmental fees, licenses and inspections necessary for the proper execution
and completion of the Subcontract Work.  The Subcontractor shall also comply
with federal, state and local tax laws, social security acts, unemployment
compensation acts and worker's or workmen's compensation acts insofar as
applicable to the performance of this Subcontract.

                                         5

<PAGE>

          (4)  within twenty-four hours after receiving written notice from
the Contractor to that effect, proceed to remove from the Project site all
materials condemned by the Contractor or the Owner's construction lender,
whether worked or unworked, and to take down all portions of the Subcontract
Work which the Contractor or the Owner's construction lender shall by like
written notice condemn as unsound or improper, or which in any way fails to
conform to the drawings or specifications for the Project. The Subcontractor
shall make good all work damaged or destroyed thereby.

          (5)  at all times keep the Project site free from accumulation of
waste material and rubbish resulting from operations under this Subcontract
and shall at completion clean up and remove from the Project site all rubbish
and debris resulting from the performance of the Subcontract Work.

          (6)  coordinate the Subcontract Work with all subcontractors
provided however that the Contractor may, at its election, control and direct
such coordination.  In carrying out its Subcontract Work the Subcontractor
shall take all necessary precautions to protect the finished work of other
trades from damage caused by its operation.

          (7)  not employ any persons in the performance of this Subcontract
whose employment might be reasonably objected by the Contractor or Owner. In
the interest of harmonious relations and to facilitate the orderly and
efficient progress of the work on this Project, the Subcontractor hereby
agrees to promptly remove from the Project any supervisor, employee, workman
or subcontractor to whom the Contractor reasonably objects and such person or
party shall not again be employed in an portion of the Subcontract Work.

          (8)  abide by the safety rules and regulations established by the
Contractor or promulgated by any federal, state or local government body or
agency with appropriate jurisdiction.

     B.   The Subcontractor shall not sell, let, assign or transfer this
Subcontract, or any part of the Subcontract Work, or any balances or sums of
money due or to become due and payable hereunder, without the written consent
of the Contractor which consent may be withheld by the Contractor for any
reason or no reason.

     C.   In the event of any failure of the Subcontractor to complete the
Subcontract Work within the required time or upon the dates set forth on
Exhibit "A", the Subcontractor shall pay to the Contractor such damages as
the Contractor may sustain by reason of any such delay directly or indirectly
attributable to or caused by the Subcontractor, including but not limited to,
recovery of the Contractor's overhead and expense related to managing and
supervising the Principal Contract work during or equal to any period of time
resulting from such delay of the Subcontractor; and the Subcontractor further
agrees that neither the payment of such damages nor any liability incurred
for the payment of such damages shall release the Subcontractor from its
obligation to otherwise fully perform this Subcontract; provided however,
that the Contractor, in its sole discretion, may in addition to and not in
lieu of any foregoing right or remedy immediately and without further notice
to the Subcontractor terminate this Subcontract. The Subcontractor further
agrees that the Contractor may set-off against any sums due from the
Contractor to the Subcontractor for work performed, all damages or
reimbursements payable from the Subcontractor to the Contractor pursuant to
the terms of this Agreement.

                                       6
<PAGE>

     D.   If at any time the Contractor in its sole discretion determines
that the Subcontractor's financial condition has become impaired, unstable or
unsatisfactory, the Contractor shall have the option to immediately cancel
this Subcontract or to initiate such other action as the Contractor may, in
its sole discretion, deem necessary for the protection or preservation of its
interests and/or the prevention of delay in the efficient and or delay
progress of work on the Project, including but not limited to that portion of
such work to be performed by Subcontractor hereunder. In the event of such
cancellation, the rights of the Contractor shall be the same as if the
Subcontractor has willfully refused to further perform this Subcontract.

     E.   It is acknowledged that the Subcontract Work provided for in this
Subcontract constitutes only a part of the work being performed on this
Project for the Owner by the Contractor and other subcontractors. The
Subcontractor therefore agrees to perform the Subcontract Work in such a
manner that it will not injure or damage any other work performed by the
Contractor or any other subcontractor, and Subcontractor further agrees:

          (1)    to furnish continuous and effective protection at all times
for its work in place and all materials stored for use under this Subcontract
and to bear and be solely liable for all loss and/or damage of any kind to it
in connection with said work and [ILLEGIBLE] liable for all loss and/or
damage of any kind to or in connection with said work and materials at any
time [ILLEGIBLE] final completion and acceptance thereof unless said loss or
damage is caused solely by the negligence [ILLEGIBLE] and is subject to
recovery [ILLEGIBLE] applicable insurance policies as may be in effect.

          (2)    to furnish [ILLEGIBLE] be required to adequately protect the
work in place and the property of the [ILLEGIBLE] other subcontractors from
damage or injury as a result of its execution of this [ILLEGIBLE] from its
operations hereunder.

          (3)    to report to [ILLEGIBLE] any damage to its property or work
in place, describing such damage and circumstances [ILLEGIBLE] available, an
estimate of the cost of restoration and identification of the [ILLEGIBLE]

          (4)    to repay or [ILLEGIBLE] any damage or injury to the work or
property of the Owner, the Contractor and [ILLEGIBLE] to the work or the
property of the Owner, the Contractor and other [ILLEGIBLE] by or arising
from the performance of its subcontract work, including the cost of
replacing, [ILLEGIBLE] removed or displaced in the course of correcting or
repairing work [ILLEGIBLE] rejected by the Owner or the Owner's construction
lender or which are [ILLEGIBLE] of this [ILLEGIBLE].

   F.     Whenever it may [ILLEGIBLE] Contractor to [ILLEGIBLE] Contractor
shall be permitted to occupy and/or use any [ILLEGIBLE] of the Subcontract
Work which has been either partially or fully completed by the Subcontractor
before [ILLEGIBLE] inspection and acceptance thereof by the Owner, but such
use and/or occupation shall not relieve the Subcontractor of its guarantee of
said work and materials nor of its obligation to make good at its own expense
any defect in materials and workmanship which may occur or develop prior to
the Contractor's release from responsibility to the Owner, provided, however,
the Subcontractor shall not be responsible for the maintenance of such
portion of work as may be used and/or occupied by the Contractor, not for
any damage thereto that is due to or caused by the Contractor during such
period of use.

   7.     MECHANICS' LIEN AND CLAIMS.

          A.   The Subcontractor any person or persons acting through or
under the Subcontractor shall not file or maintain any mechanics' claims or
liens against the Project, or any of the building included in the he Project,
or the ground which the Subcontract Work is to be performed, for or on
account of any work done or materials furnished by the Subcontractor and any
such person or persons as aforesaid for the Subcontract Work under this
Subcontract, or otherwise. The Subcontractor, for and on behalf of the
Subcontractor any other person or persons as aforesaid, hereby expressly
waive and relinquish the right to have, file or maintain any mechanics'

                                       7
<PAGE>

claim or lien against the Project, the buildings included in the Project and
the ground upon which the Subcontract Work is to be performed, or any of
them, which waiver shall be and hereby is made an independent covenant and
shall operate and be effective also with respect to work and labor done and
materials furnished under any supplemental agreement between the Contractor
and Subcontractor, or any agreement for extra work done, performed, furnished
or supplied in and about the Project, although not therein referred to as
work and labor performed and materials furnished under this Subcontract.
Upon the execution of this Subcontract, the Subcontractor shall properly
execute and deliver to the Contractor a waiver of liens in the form supplied
to it by the Contractor.

          B.   The Subcontractor when required by the Contractor as a
condition precedent to the making of the final payment hereunder, shall
furnish to the Contractor a full and complete release and discharge, in a form
satisfactory to the Contractor, of all liens, claims, and demands arising out
of or relation to the Subcontract Work and any and all materials furnished,
work done and equipment used in connection therewith. Furthermore, if, prior
to final payment, the Owner or any party providing financing for the Project
requests a release of liens from the Subcontractor, the Subcontractor shall
execute and deliver such release of lien in a form satisfactory to the Owner
or such other party.

   8.     DEFAULT.

          A.   If the Subcontractor fails to comply, or becomes unable to
comply, or with reasonable probability (as determined solely by Contractor)
will become unable to comply with any of the provisions of this Subcontract;
or if the Subcontractor fails at any time to supply a sufficient number of
properly skilled workmen or sufficient supplies, materials, machines,
equipment or plant of proper quality or fails in any respect to prosecute the
Subcontract Work with promptness and diligence, or cause by any action or
omission a stoppage of, delay in, or interference with the work of the
Contractor or other subcontractors of the Contractor; or if the Subcontractor
abandons the Subcontract Work, or any part thereof, the Contractor may, in
addition to and without prejudice to any other right or remedy, terminate
this Subcontract and immediately without notice to Subcontractor take over
and complete the performance of the Subcontract Work to have been performed
hereunder at the expense of the Subcontractor, or the Contractor may, without
terminating this Subcontract taking over the Subcontract Work, immediately
and without notice to the Subcontractor, furnish the necessary materials and
labor by itself or through others, to remedy the situation, all at the
expense of the Subcontractor.  The parties hereto further agree that any of
the following shall, without limitation, at the option of the Contractor,
constitute inability to comply with the provisions of this Subcontract for
purposes of this Article: (a) the filing of a petition in bankruptcy or a
petition for the appointment of a receiver by or against the Subcontractor;
or (b) the insolvency of the Subcontractor or its inability to meet its debts
as they mature; or (c) the establishment of a committee of creditors
involving the Subcontractor's business or assets, or the making of an
assignment for the benefit of Subcontractor's creditors, or (d) the failure
or refusal of the Subcontractor to respond by written reply to or by
satisfactory compliance with, any written order or notice duly issued by the
Contractor.

          B.   If the Subcontractor shall be adjudged bankrupt, or make a
general assignment for the benefit of creditors, or a Receiver be appointed
on account of the insolvency of the Subcontractor, or if the Subcontractor at
any time refuses or neglects to supply a sufficient number of properly
skilled and other workmen and equipment or an adequate amount of materials of
the proper quality, as required by the Contractor, or fails to make prompt
payment for materials, labor or equipment furnished and supplied in the
performance of the Subcontract Work, or fails to submit to the Contractor
satisfactory evidence of the payment by the Subcontractor of all indebtedness
incurred for material labor and equipment included in any previous monthly
statement or fails in the performance of any of the agreements herein
contained, the Contractor has the right, without prejudice to any other right
or remedy available to the Contractor on forty-eight (48) hours written
notice to the Subcontractor, either to provide any such labor, materials or
equipment and deduct the cost thereof from any payments then or thereafter
due to the Subcontractor, or to terminate the employment of the Subcontractor
for the Subcontract Work and to enter upon the Project site and take
possession, for the purpose of completing the Subcontract Work, of all
materials, tools and appliances thereon and to employ any other person or
persons to finish the Subcontract

                                       8
<PAGE>

Work and to provide the materials therefor; and in case of such
discontinuance of the employment of the Subcontractor, the Subcontractor
shall not be entitled to receive any further payment under this Subcontract.

After the work under the principal contract has been finished and accepted, if
the expense incurred by the Contractor in finishing the Subcontract Work exceeds
the unpaid balance of the amount to be paid under this Subcontract, the
Subcontractor shall pay the difference to the Contractor.

     9.   MISCELLANEOUS

          A.   The waiver by the Contractor of any breach or default of this
Subcontract by the Subcontractor shall not be construed as a waiver of any other
breach or default of the same or any other terms, conditions, provisions or
covenants of this or any other agreement between the parties hereto. Forbearance
from demanding strict compliance with any term or provision of this Subcontract
or any other agreement between the parties hereto shall not operate as a waiver
and shall not prevent the Contractor from subsequently demanding strict
compliance therewith.

          B.   Disputes which may arise hereunder between the Contractor and the
Subcontractor shall not interfere with the diligent performance by the
Subcontractor of the Subcontract Work.

          C.   The laws of the Commonwealth of Pennsylvania shall be applicable
to this Subcontract and shall be used to decide any dispute related to this
Subcontract.

          D.   The Subcontractor agrees that the sole and exclusive venue for
any suit brought by it against the Contractor shall be Delaware County,
Pennsylvania.

          E.   The Contractor and the Subcontractor, and their heirs, executors,
administrators, successors and assigns shall be bound by and shall fully perform
the covenants herein contained.

          F.   Any and all notices given hereunder shall be in writing and shall
be sent by certified mail, return receipt requested, addressed as follows:

               If to Contractor:

               BALDWIN OFFICE, INC.
               555 NORTH LANE, SUITE # 6101
               CONSHOHOCKEN, PA 19428

               If to Subcontractor:
               ______________________________
               ______________________________
               ______________________________

                                        9

<PAGE>

or to such other address or addresses as either of the parties hereto shall
notify the other in accordance with the terms of this Agreement.

                              CONTRACTOR

                              BALDWIN OFFICE, INC.

ATTEST:__________________     BY: ____________________

                              SUBCONTRACTOR

ATTEST:   ________________    BY: ____________________

                                       10
<PAGE>

                                   GUARANTEE

     The undersigned hereby jointly and severally guarantee to the Contractor
the performance of all of the Subcontractor's obligations at the time and in the
manner provided for in the foregoing Subcontract including, but not limited to,
payment of any sums which the Subcontractor may be required to pay the
Contractor because of the Subcontractor's breach of the foregoing Subcontract.

     The undersigned hereby irrevocably authorize and empower any attorney or
attorneys or the Prothonotary or Clerk of the Court of record in the
Commonwealth of Pennsylvania or elsewhere if the Subcontractor becomes obligated
to pay any sum to the Contractor under the terms of the foregoing Subcontract
and fails or refuses to do so within ten (10) days of receipt of notice of
demand for such payment to appear for and to confess judgment therein against
the undersigned for the unpaid amount due the Contractor, together with
interest at the rate of twelve percent (12%) per annum from the date of judgment
until actual payment is obtained by the Contractor. The undersigned hereby
waivers and relinquishes all errors, defects and imperfections in the entry of
judgment as aforesaid, or in any proceeding pursuant thereto. If a copy hereof,
verified by affidavit, shall be filed in said proceedings, it shall not be
necessary to file the original as a warrant of attorney. The Warrant of Attorney
to Confess Judgment hereunder shall not be extinguished by one or more exercises
thereof, but may be exercised from time to time until all of the Subcontractor's
obligations to the Contractor under the foregoing Subcontract are paid in full.

Witnessed by:

____________________________________   __________________________________(SEAL)

____________________________________   __________________________________(SEAL)

                                        11
<PAGE>

                                     EXHIBIT "A"

                         DESCRIPTION OF SUBCONTRACT WORK AND
                     DATE FOR COMPLETION OF THE SUBCONTRACT WORK

     A.   DATE OF COMPLETION.

          The Subcontractor shall complete the Subcontract Work on or before the
31st day of August, 1995.

     B.   The Subcontract Work shall consist of the following:

                                       12

<PAGE>

                           IN THE COURT OF COMMON PLEAS
                          DELAWARE COUNTY, PENNSYLVANIA

BALDWIN OFFICE ASSOCIATES, L. P.        :
A Pennsylvania Limited Partnership      :
                                        :
          Owner-Plaintiff               :
     v.                                 :
                                        :
-----------------------------------     :
          Subcontractor-Defendant       :
                                        :
AND                                     :

-----------------------------------     :
          Subcontractor-Plaintiff       :
     v.                                 :
                                        :
BALDWIN OFFICE ASSOCIATES, L. P.        :
A Pennsylvania Limited Partnership      :
                                        :
          Owner-Defendant               :

                                WAIVER OF LIENS

THIS WAIVER OF LIENS ("Waiver") is made this _______ day of______________,
1995 by _________________ (the "Subcontractor") in favor of BALDWIN OFFICE
ASSOCIATES, L. P. (the "Owner").

WHEREAS, the Owner is the legal owner of the real estate located in the
BOROUGH OF EDDYSTONE, with an address of 1510 CHESTER PIKE, EDDYSTONE, PA
(the "Property"); and

WHEREAS, by an agreement dated July 7, 1995 ("Agreement"), Owner and Baldwin
Office, Inc. ("General Contractor") contracted for the construction and
completion of certain improvements on the Property as more fully described in
the Agreement ("Improvements"); and

WHEREAS, by the terms of the Agreement, General Contractor has agreed that no
mechanics or materialman's lien or claim would be filed or maintained on the
Property or any part thereof, either by itself or anyone else for or on
account of any work, labor, or materials supplied in the performance of the
Agreement, or under any supplemental contract for extra work, in the
construction or completion of the Improvements on the Property; and

WHEREAS, prior to the date of this Waiver, General Contractor has executed
and delivered to Owner a waiver of liens similar to this Waiver; and

WHEREAS, the Subcontractor excecuted a contract with the General Contractor
(the "Contract") to provide labor, work, materials and/or supplies at the
Property, and the Contract requires the Subcontractor to execute a waiver of
liens.

NOW THEREFORE, in consideration of the mutual covenants and agreements
contained herein and in the Contract, the parties hereto, intending to be
legally bound hereby, agree as follows:

                                       13

<PAGE>

     1.   The Subcontractor, for itself and anyone else acting or claiming
through or under it, hereby waives and relinquished all right to file a
mechanics' lien, claim or notice of intention to file any lien or claim, and
hereby covenants, promises and agrees that no mechanics' lien or claim or
other lien or claim of any kind whatsoever shall be filed or maintained
against the Improvements or the estate of title of Owner in the Property or
curtilage or curtilages appurtenant thereto, by or in the name of
Subcontractor or any subcontractor, materialmen or laborers for work done or
materials furnished under the Contract or by any of them for and about the
Improvements or the Property or any part thereof, or on credit thereof, so
that there shall not be any legal or lawful claim of any kind whatever
against the Owner for any work done or labor or materials furnished under the
Contract for and about the erection, construction and completion of the
Improvements, or under any contract for extra work, or for work supplemental
thereto, or otherwise.

     2.   This Waiver waiving the right of lien shall be an independent covenant
and shall operate and be effective as well with respect to work done and
materials furnished under any supplemental contract for extra work in the
erection, construction and completion of the Improvements as to any work and
labor done and materials furnished under the Contract.

     3.   In order to give the Owner full power and authority to protect
themselves, the Improvements, the Property, the estate or title of the Owner
therein, and the curtilage or curtilages appurtenant thereto against any and all
liens or claims filed by the Subcontractor or anyone acting under or through him
in violation of the foregoing covenant, the Commonwealth of Pennsylvania, to
appear as attorney for it, them, or any of them, in any such Court and in its or
their name or names, (a) to the extent permitted by law, mark satisfied of
record at the cost and expense of the Subcontractor or of any subcontractor,
materialman, any and all claim or claims, lien or liens, filed in violation of
the foregoing covenant, or (b) cause to be filed and served in the name of
Subcontractor or any subcontractor or anyone else acting under or through if any
pleading or instrument, or any amendment to any pleasing or instrument
previously filed by it or them, to incorporate therein, as part of the record,
the waiver contained in this instrument, and for such act or acts, a copy of
this executed instrument shall be good and sufficient warrant and authority, and
a reference to the court, term and number in which and where this Waiver stall
have been filed shall be sufficient exhibit of the authority herein contained to
warrant such action, and the Subcontractor does hereby remise, release and
quitclaim all rights and all manner of errors, defects and imperfections
whatsoever in entering such satisfaction or in filing such pleading, instrument
or amendment, or in any way concerning them.

     4.   The Subcontractor hereby warrants that no work or labor of whatsoever
kind or nature, has as yet been done and that no materials or services
whatsoever have as yet been furnished by anyone, under, towards or in connection
with the execution or performance of said Contract.

     5.   This Waiver shall bind the Subcontractor and its successors and
assigns.

     IN WITNESS WHEREOF, the Subcontractor has caused this Waiver of Liens to be
duly executed the day and year first written above written.

                                   CORPORATE SUBCONTRACTOR

ATTEST                             ---------------------------

                                   By:
----------------------                 -----------------------

                                   Its:
                                       -----------------------
[CORPORATE SEAL]

WITNESS:                           INDIVIDUAL SUBCONTRACTOR

                                                              (SEAL)
---------------------------        ---------------------------
                                   PRINTED INDIVIDUAL SUBCONTRACTOR NAME

                                      14

<PAGE>

                       FOURTH AMENDMENT TO LEASE

-------------------------------------------------------------------------------

THIS FOURTH AMENDMENT TO LEASE ("FOURTH AMENDMENT") is made this 29 day of
October, 1996 between BALDWIN OFFICE ASSOCIATES, L.P. ("LANDLORD") and
NEPTUNE SYSTEMS, INC. ("TENANT").

                                     BACKGROUND

A.   Landlord and Tenant are parties to that certain Lease ("LEASE") dated April
     3, 1995, pursuant to which Landlord leased to Tenant approximately 5,366
     square feet of space (the "ORIGINAL LEASED PREMISES") on the sixth floor of
     the building ("BUILDING") known as Baldwin Tower located at 1510 Chester
     Pike, Eddystone, Pennsylvania.  The Lease was amended pursuant to that
     certain Lease Amendment dated July 6, 1995 (the "FIRST AMENDMENT") and was
     further amended pursuant to that certain Amendment to Lease dated June 17,
     1996 (the "SECOND AMENDMENT"), and was further amended pursuant to that
     certain Amendment to Lease dated June 26, 1996 (the "THIRD AMENDMENT").

B.   The Second Amendment expanded and relocated the Demised Premises to 13,980
     square feet on the third floor of the Building which was referred to as the
     "NEW DEMISED PREMISES", and the Tenant relinquished its rights in the
     Original Leased Premises.

C.   The Third Amendment includes the Originals Leased Premises with the New
     Demised Premises as part of Tenant's leasehold interest under the Lease for
     a total size of the Demised Premises of 19,346 sq. ft.

D.   The parties desire to amend the Lease to revise the construction procedures
     for the New Demised Premises and the payment for those improvements.

          NOW, THEREFORE, in consideration of the mutual covenants contained
herein, the parties hereto, intending to be legally bound, hereby agree as
follows:

1.   Tenant will hire a third party (the "TENANT'S GENERAL CONTRACTOR") to
     oversee the construction of the New Demised Premises to be built in
     accordance with the plans and specifications drawn by Collaborative Design
     dated September 20, 1996. Landlord will not be responsible for any portion
     of the construction or any timing delays that may occur. Prior to any work
     being commenced, Tenant's General Contractor and any subcontractors they
     may employ must sign a Waiver of Liens for the Landlord and deliver
     certificates of insurance confirming Tenant's General Contractor is
     adequately insured in Landlords reasonable opinion. All work must be
     coordinated with the building manager.

2.   Landlord shall pay Tenant's General Contractor for work completed, on a
     monthly basis, an amount not to exceed the Relocation Cost plus an
     additional Seventy Five Thousand Dollars ($75,000.00) for a total of
     $332,695.20. Landlord may retain ten percent of this amount until all work
     is completed and final inspection by proper authorities have been made and
     passed. Tenant's General Contractor must submit completed draw forms "AIA
     G702" and "AIA G703" to Landlord in order to receive payment.
<PAGE>
3.   Tenant agrees to pay, as additional rent, One Thousand Ninety Dollars and
     Forty Cents per month ($1,090.40) for the remainder of the Lease Term as
     repayment for Landlord's additional contribution of $75,000.00, plus 12%
     interest amortized over the balance of the Lease Term.

4.   Tenant's General Contractor is obligated to pay all subcontractors for work
     completed, and Landlord shall have the right to pay all subcontractors
     directly for work performed in lieu of Tenant's General Contractor.

5.   Tenant's Fraction noted in the Lease shall be 19,346/166,250 (i.e. 11.6%).

6.   The Term of the Lease shall end on July 31, 2006 unless sooner terminated
     as provided in the Lease and/or Third Amendment.

7.   The Schedule "A" Rent Rider to the Lease and Lease Amendment dated July 6,
     1995, Second Amendment dated June 17, 1996 and Third Amendment dated June
     26, 1996 changes to the following:

<TABLE>
<CAPTION>

              PERIOD                       MONTHLY        ANNUALLY
              ------                       -------        --------
    <S>                                  <C>            <C>
    November 1, 1996 - July 31, 1997     $23,555.40     $282,664.80
    August 1, 1997 - July 31, 2001       $27,020.40     $324,244.80
    August 1, 2001 - July 31, 2006       $28,632.57     $343,590.84
</TABLE>

     This schedule includes the additional rent noted in section 3 of this
     Fourth Amendment.

8.   The terms and conditions of the Lease as modified hereby shall remain in
     full force and effect and are hereby ratified, confirmed, and reaffirmed
     for all purposes and in all respects. All capitalized words not otherwise
     defined herein shall have the meanings as defined in the Lease, the First
     Amendment, the Second Amendment or the Third Amendment.

9.   Landlord shall guarantee that existing HVAC (heating and cooling) units
     supply enough tonnage to properly cool the Premises to a maximum of 80
     degrees Fahrenheit.  In the event that the HVAC units prove inadequate to
     the task (as determined by and independent engineering consultant selected
     jointly by Landlord and Tenant), Landlord shall, at Landlord's expense
     provide additional cooling units to achieve the 80 degree threshold.

AGREED AND ACCEPTED

/s/ [illegible]                         /s/ [illegible]
-----------------------------------     -----------------------------------
NEPTUNE SYSTEMS, INC.                   BALDWIN OFFICE ASSOCIATES, L.P.

DATE:   10/29/96                          DATE:   10/23/96
<PAGE>

                      EXPANSION, EXTENSION & RELOCATION
                                 AMENDMENT

-------------------------------------------------------------------------------
-------------------------------------------------------------------------------

This Amendment dated ___________ to be made part of a certain Lease ("LEASE")
dated APRIL 3, 1995 between BALDWIN OFFICE ASSOCIATES, L.P. (henceforth called
"Landlord") and NEPTUNE SOFTWARE (henceforth called "Tenant") for OFFICE space
in the BALDWIN TOWER OFFICE BUILDING, EDDYSTONE, PENNSYLVANIA as more
particularly described below:

1.   The Demised Premises defined in Section 1 of the Lease changes to 13,980
     rentable square feet on the third floor of the Building, known as suite
     640.

2.   The Term defined in Section 2 of the Lease shall be ten (10) years and two
     weeks commencing on July 15, 1996 and ending on July 31, 2006.

3.   Schedule "A" Rent Rider changes to the following:

<TABLE>
<CAPTION>

              PERIOD                       MONTHLY        ANNUALLY
              ------                       -------        --------
    <S>                                  <C>            <C>
    July 15, 1996 - July 31, 1997        $15,757.50     $189,090.00
    August 1, 1997- July 31, 2001        $19,222.50     $230,670.00
    August 1, 2001 - July 31, 2006       $20,387.50     $244,650.00
</TABLE>

4.   Tenant's fraction defined in Section 4(a)(iii) changes to 13,980/166,250
     (i.e. 8.41%)

5.   Landlord shall improve the Demised Premises according to the attached plan
     drawn by T. E. Hall Architects dated May 28, 1996, Revision #2. The cost of
     such buildout which includes a contribution for office furniture of
     $27,995.20, a moving allowance of $5,000.00 and an improvement allowance of
     $15.00 per rentable square foot ($209,000.00) shall be borne by the
     Landlord.

     In the event that the actual costs for improvements are greater than
     $242,695.50 but less than $271,303.00, the portion which is greater than
     $242,695.50 will be paid 50% by the Landlord and 50% by the Tenant. In the
     event the actual costs for improvements is greater than $271,303.00, the
     portion which is greater than this amount will be paid entirely by the
     Tenant.

6.   Tenant shall be notified of any unit which becomes available on the second,
     third or fourth floor of the Building - prior to such space being leased to
     a third party. However, Tenant shall not have a right of first refusal with
     regard to such space.
<PAGE>

7.   Provided that Tenant is not in default of any of the terms or conditions of
     the Lease; as amended hereby, and Landlord is unable to provide additional
     square footage in the Building sufficient to accommodate the reasonable
     expansion needs of Tenant, Tenant may buy out of this Lease by providing
     one year's prior written notice to Landlord, of Tenant's intention to
     terminate the Lease and paying, at the time of such notice, an amount equal
     to:

          A.   The cost of improvements, commissions, and free rent period
               associated with this Amendment that will remain unamortized over
               the balance of the lease term assuming an interest rate of ten
               percent (10%) at the time of the notice; plus

          B.   A Lease Cancellation Payment in accordance with the following
               schedule:

<TABLE>
<CAPTION>
   Lease year during which notice is given      Payment amount
   ---------------------------------------      --------------
   <S>                                          <C>
                  1                             2 1/2 yrs. rent
                  2                             2 1/4 yrs. rent
                  3                                2 years rent
                  4                             1 3/4 yrs. rent
                  5                             1 1/2 yrs. rent
                  6                             1 1/4 yrs. rent
                  7                                1 years rent
                  8                              3/4 years rent
                  9                              1/2 years rent
                  10                               0 years rent
</TABLE>

8.   Upon Tenant's relocation to the third floor, all partition furniture in the
     sixth floor space will become the property of the Landlord.

9.   All other terms and conditions of the Lease shall remain in full force and
     effect.

AGREED AND ACCEPTED

-----------------------------------     -----------------------------------
NEPTUNE SOFTWARE                        BALDWIN OFFICE ASSOCIATES, L.P.

DATE:   /  /                            DATE:   /  /

<PAGE>

                                 RELOCATION AMENDMENT

This Amendment dated MARCH 25, 1997 to be made part of a certain Lease dated
APRIL 3, 1995 between BALDWIN OFFICE ASSOCIATES, L.P. (henceforth called
"Landlord") and NEPTUNE SYSTEMS INC. (henceforth called "Tenant") for OFFICE
space in the BALDWIN TOWER BUILDING, EDDYSTONE, PA as more particularly
described below:

1.   Tenant shall return 5,366 rentable square feet in the southwing of the 6th
     floor of the building and shall lease an additional 3,090 rentable square
     feet in the southwing of the 3rd floor of the building.

2.   The Commencement Date for this Amendment shall be May 1, 1997.

3.   Tenant's proportionate share shall noted in Section 4(a)(iii) shall change
     to 17,070/166,250.

4.   Minimum Rent shall be based on the following schedule:

<TABLE>
<CAPTION>

     PERIOD              MONTHLY             ANNUALLY            PER SF
     ------              -------             --------            ------

     <S>                 <C>                 <C>                 <C>
     5/1/97-7/31/97      $20,783             $249,396            $14.61
     8/1/97-7/31/01       23,842              286,104             16.76
     8/1/01-7/31/06       25,264              303,168             17.76
</TABLE>

5.   Tenant shall lease the space in "AS IS" condition.

6.   All other terms and conditions contained in the Lease shall remain in full
     force and effect, including but not limited to the default provisions
     contained in Section 15.

7.   Four parking spaces dedicated to Neptune.

/s/ [illegible]                                    /s/ [illegible]
-------------------------------                    ------------------------
BALDWIN OFFICE ASSOCIATES, L.P.                    NEPTUNE SYSTEMS INC.

Date:   4/29/97                                    Date:   4/18/97

<PAGE>

                           FIFTH AMENDMENT TO LEASE REVISED

This Revised Fifth Amendment to Lease ("Fifth Amendment Revised") is made
this 23 day of March, 1998 between BALDWIN OFFICE ASSOCIATES, L.P
("Landlord") and EXE TECHNOLOGIES, INC. ("Tenant").

                                      BACKGROUND

A.   Landlord and Tenant are parties to that certain Lease ("Lease") dated
     April 3, 1995, pursuant to which Landlord leased to Tenant approximately
     5,366 square feet of space (the "Original Leased Premises") on the sixth
     floor of the building ("Building") known as Baldwin Tower located at
     1510 Chester Pike, Eddystone, Pennsylvania.  The Lease was amended pursuant
     to that certain Lease Amendment dated July 6, 1995 (the "First Amendment")
     and was further amended pursuant to that certain Amendment to Lease dated
     June 17, 1996 (the "Second Amendment"), and was further amended pursuant to
     that certain Amendment to Lease dated June 26, 1996 (the "Third
     Amendment").

B.   The Second Amendment expanded and relocated the Demised Premises to 13,980
     square feet on the third floor of the Building which was referred to as the
     "New Demised Premises", and the Tenant relinquished its rights in the
     Original Leased Premises.

C.   The Third Amendment includes the Original Leased Premises with the New
     Demised Premises as part of Tenant's leasehold interest under the Lease for
     a total size of the Demised premises of 19,345 square feet.

D.   The Fourth Amendment amended the Lease to revise the construction
     procedures for the New Demised Premises and the payment for those
     improvements.

E.   The Relocation Amendment changed the Tenant's proportionate share to
     17,070/166,250.

F.   The Fifth Amendment to Lease amended the Lease to add 2,908 square feet
     located on the sixth floor to the Demised Premises for a total of 22,254
     square feet.

G.   The parties derive to correct the square footage and rent schedule noted in
     the Fifth Amendment to the following.

<PAGE>

NOW THEREFORE, in consideration of the mutual covenants contained herein, the
parties hereto, intending to be legally bound, hereby agree as follows:

1.   As of March 9, 1998 the 2,908 square feet on the sixth floor of the
     building (Exhibit "A" attached) will become part of the Demised Premises
     as outlined in the Lease. The total space known as the Demised Premises
     will become 19,978 square feet.

2.   The Schedule "A" Rent Rider of the Lease and Lease Amendment dated July 6,
     1995, Second Amendment dated June 17, 1996, Third Amendment dated June 26,
     1996, Fourth Amendment dated October 29, 1996 and Relocation Amendment
     dated March 25, 1997 changes to the following:

<TABLE>
--------------------------------------------------------------------------------
                PERIOD                        MONTHLY             ANNUALLY
--------------------------------------------------------------------------------
<S>                                          <C>                 <C>
     April 1, 1998 - July 31, 2001           $27,737.82          $332,853.84
--------------------------------------------------------------------------------
     August 1, 2001 - July 31, 2006          $29,402.65          $352,831.80
--------------------------------------------------------------------------------
</TABLE>

3.   Tenant's Fraction noted in the Lease shall be 19,978/166,250.  (i.e 12.02%)

4.   The term of the Lease shall end on July 31, 2006 unless
     sooner terminated as provided in the Lease and/or Third Amendment.

5.   The terms and conditions of the Lease as modified hereby shall remain in
     full force and effect and are hereby ratified, confirmed and reaffirmed
     for all purposes and in all respects. All capitalized words not otherwise
     defined herein shall have the meanings as defined in the Lease. The
     First Amendment, the Second Amendment, the Third Amendment or the Fourth
     Amendment.

AGREED AND ACCEPTED:

/s/ [ILLEGIBLE]                    /s/ [ILLEGIBLE]
-----------------------            ------------------------------
EXE Technologies, Inc.             Baldwin Office Associates, L.P
Date: March 23, 1998               Date: March 23, 1998

<PAGE>

                                      EXHIBIT A

                                        [MAP]

                            BALDWIN TOWERS - SIXTH FLOOR
                      ------------------------------------------
                          1510 Chester Pike, Eddystone, PA

                       Preferred Real Estate Investments, Inc.
                                  (610) 834-1969

                         [LOGO] THOMAS E. HALL, ARCHITECTS

<PAGE>

                                    AMENDMENT

This Amendment to the Lease dated April 3, 1995 between Neptune Systems, Inc.
and Baldwin Tower Associates, L.P. is dated November 8, 1999. EXE Technologies,
Inc. is the successor by merger to Neptune Systems, Inc.

Whereas EXE intends to lease storage space located in the basement of the
premises.

Now, therefore, both parties agree to the following:

1.   EXE shall lease approximately 120 square feet of storage space as of
     11/1/99.

2.   EXE shall remit $70.00 a month for the above space.

3.   The term of the lease for the storage space shall be coterminous with the
     original lease.

4.   All other terms and conditions contained in the lease and any other
     amendment shall remain in full force and effect including but not limited
     to the default provisions contained in Section 15.

Baldwin Office Associates, LP             EXE Technologies, Inc.

By: /s/ [illegible]                       By: /s/ Christopher F. Wright
    ------------------------------            ----------------------------------

Date:  11/11/99                           Date:  11/5/99
     -----------------------------              --------------------------------

<PAGE>

November 27, 1996

Neptune Systems, Inc.
640 Baldwin Tower
Eddystone, PA  19022
Attn:  Jonie Parker

         RE:      AGREEMENT OF LEASE DATED APRIL 3, 1995, AS AMENDED ("LEASE")
                  BETWEEN NEPTUNE SYSTEMS, INC. ("TENANT") AND BALDWIN OFFICE
                  ASSOCIATES, L.P. ("LANDLORD")

Dear Joni:

          The purpose of this letter is to clarify the following inconsistancies
that have arisen as a result of the many amendments that have been made to the
Lease:

          1)   Tenant's termination option set forth in the Amendment to Lease
               dated June 17, 1996 supercedes and replaces Tenant's termination
               option set forth in the Lease Amendment dated July 6, 1995.

          2)   Tenant's right of first offer to lease contiguous space on the
               sixth floor has been terminated and replaced with Tenants right
               to be a first offered available space on the second, third or
               fourth floors.

          Please confirm that the foregoing is accurate by signing the enclosed
copy of this letter and return it to me.

                                                  Sincerely,

                                                  /s/ John McGee
                                                  ----------------------------
                                                  John McGee

    Acknowledged and Agreed
    this ____ day of December, 1996

    NEPTUNE SYSTEMS, INC.

    By:  /s/ Raymond R. Hood
        --------------------------
    Its:  President
        --------------------------

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00008-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00008-of-00352.parquet"}]]