Document:

Exhibit 10.9

 

CONSTRUCTION LOAN AGREEMENT

 

 

THIS AGREEMENT, made the 7th day of November, 2003, by
and between WACHOVIA BANK, NATIONAL ASSOCIATION, a national banking association
with an office at PA1245, 123 South Broad Street, Philadelphia, Pennsylvania 19109
(“Lender”) and ORLEANS AT LAMBERTVILLE, LLC, a New Jersey limited liability
company with an office at 300 East Park Avenue, Suite 8, Hainesport, New
Jersey  08036 (“Borrower”).

 

W I
T N E S S E T H :

 

A.            Borrower
is or is about to be the owner of certain real estate consisting of
approximately 55 acres of land (the “Real Estate”) located in the City of
Lambertville, Hunterdon County, New Jersey, such land being the development to
be known as Lambert’s Hill, and containing townhouse building lots (each a
“Lot”).  The Real Estate is more fully
described in the mortgage referred to in Section 2 hereof.

 

B.            Borrower
desires to construct or cause to be constructed, within the time hereinafter
set forth, a total of one hundred twenty-nine (129) townhouse dwellings (each a
“Dwelling”), within a total of 42 structures (each a “Building”) and various
on-and-offsite improvements to serve the Dwellings (the “Site Improvements”);
the Buildings, Site Improvements and Dwellings being sometimes referred to
herein collectively as the “Improvements”, in accordance with certain plans and
specifications (the “Plans and Specifications”), copies of which, initialed by
Borrower for identification purposes, have been deposited with Lender (the
“Project”).

 

C.            In
connection with the development of the Real Estate with the Improvements,
Borrower (or its predecessor in title) may enter into agreements (hereinafter
collectively called the “Municipal Agreements”) with municipal or
quasi-municipal authorities and/or suppliers of utility services.

 

D.            Borrower
has applied to Lender for a loan to finance or refinance (i) a portion of the
cost of the acquisition of the Real Estate and (ii) the cost of construction of
the Improvements and related costs.

 

NOW, THEREFORE, the parties hereto, intending to be
legally bound hereby, agree as follows:

 

1.             Loan.

 

Subject to the terms and conditions herein set forth,
Lender agrees to lend, and Borrower agrees to borrow, a sum aggregating not in
excess of $39,040,921 (the “Loan”).

 

 

2.             Security.

 

2.1.          The
Loan shall be advanced by Lender in installments as hereinafter provided, and
shall be evidenced by Borrower’s mortgage note (the “Note”) executed
simultaneously herewith.

 

2.2.          As
security for the Loan and for the obligations of Borrower hereunder, Borrower
shall deliver to Lender the following:

 

2.2.1.       A mortgage and security agreement (the
“Mortgage”) covering the Real Estate, all easements appurtenant to or
benefiting the Real Estate, the Improvements and all fixtures, machinery and
equipment necessary or incidental to the general operation and maintenance
thereof and all renewals and replacements thereof or additions thereto, all as
more specifically described in the Mortgage (all of the foregoing are sometimes
hereinafter collectively referred to as the “Mortgaged Property”).  The Mortgage shall be a continuing first
lien in the full amount of the Loan, on a good and marketable fee simple title
to the Real Estate and the other Mortgaged Property located thereon, free and
clear of all other prior liens (including mechanics’ liens, filed or unfiled),
restrictions, easements and other encumbrances and title objections that are
not approved by Lender, and shall be insured as such at Borrower’s expense by a
reputable title insurance company satisfactory to Lender.

 

2.2.2.       Such additional security agreements, financing
statements and other security instruments, creating a valid first lien upon the
aforesaid fixtures, machinery, equipment and other property now or hereafter
located upon the Real Estate as the Lender may reasonably require.

 

2.2.3.       A guaranty and suretyship agreement executed by
Orleans Homebuilders, Inc., a Delaware corporation (the “Guarantor”).

 

2.2.4.       A collateral assignment of agreements affecting
the Real Estate.

 

The documents referred to above shall be in form and
substance satisfactory to Lender.

 

3.             Construction.

 

3.1.          Borrower
shall commence construction according to the Plans and Specifications (either
directly or through a general contractor approved by Lender) promptly after
signing this Agreement and thereafter proceed diligently, employing sufficient
workmen and supplying sufficient materials so that the Improvements shall be
fully completed and ready for normal use thereof not later than (i) the
“Payment Date” (as defined in the Note) with respect to the entire
Improvements, and (ii) with respect to any Dwelling that is the subject of an
agreement of sale with a purchaser thereof, the date for completion required by
such agreement of sale.

 

3.2.          Borrower
further agrees that:

 

2

 

3.2.1.       The construction shall be performed strictly in
accordance with the Plans and Specifications and with all applicable statutes,
laws and ordinances, the requirements of all governmental authorities having
jurisdiction, and the requirements of the Insurance Service Organization (or
any other body now or hereafter constituted exercising similar functions) in
and for the locality in which the Real Estate is situated.

 

3.2.2.       Except as otherwise noted on the plans and
specifications, the Improvements when erected will be wholly on the Real Estate
within applicable building restriction lines and will not violate applicable
use or other restrictions, whether established in prior conveyances, zoning laws
or regulations or elsewhere.  Borrower
will, upon request, furnish evidence with respect thereto, together with a
foundation survey by a licensed surveyor or engineer, showing that except as
otherwise noted on the plans and specifications the construction is entirely on
the Real Estate and free from such violations and that there are no
encroachments by or on the Real Estate.

 

3.2.3.       No material amendment shall be made to the Plans
or Specifications without the written approval of the Lender and, regardless of
the nature of the amendment, of any governmental authority having jurisdiction.

 

3.2.4.       Immediately after receiving notice from Lender
or any governmental authority, Borrower will remove from the Real Estate all
materials and all portions of the construction which Lender or any governmental
authority may condemn as failing in a substantial way to conform with the Plans
and Specifications or applicable laws and will make good all portions of the
construction damaged by such removal.

 

3.2.5.       Borrower will provide to Lender facilities
commonly made available by responsible general contractors for the inspection
of the Mortgaged Property and afford full and free access to all plans,
drawings and records with respect to the construction.

 

3.3.          Lender
may at any time place a superintendent or inspector on the job, whose duties
shall be to require that the Improvements are constructed in accordance with
the Plans and Specifications.  If (and
only if) such superintendent or inspector is placed on the job after default by
Borrower, such superintendent or inspector shall be paid an amount specified by
Lender which shall be disbursed hereunder and shall be evidenced by the Note
and secured by the Mortgage.

 

3.4.          Although
Lender may inspect and approve the Plans and Specifications, cost estimates,
actual construction, and other matters pertaining to construction of the
Improvements or exercise its rights under Section 3.3 above, such inspections
or exercise of rights are solely for the protection of Lender, and Borrower
understands that Lender is not making and will not make any warranties or
representations as to any matters pertaining to the Improvements (including,
without limiting the generality hereof, the sufficiency of the construction
funds, the adequacy of the Plans and Specifications or proper performance by
any contractor or subcontractor).

 

3

 

4.             Advances.

 

4.1.          The
Loan shall be allocated in accordance with the budget set forth in Exhibit “A”
attached hereto and hereby made a part hereof (the “Loan Budget”), but Lender
may at its option reallocate the Loan, or any part thereof, among the
categories set forth in Exhibit “A” at any time and from time to time.  After an initial advance at settlement,
Borrower will request advances periodically, but not more frequently than
monthly, as the work progresses, such request to be on Lender’s customary form,
signed by any one of Benjamin D. Goldman, Joseph Santangelo, or James Thompson.

 

4.2.          Advances
may, after the occurrence of any Event of Default hereunder, be made (directly
or through a title insurer) to Borrower, any prime contractor(s),
subcontractor(s), materialman and others who have furnished goods or services
in connection with the Project, or to some or any of them, as Lender may elect
from time to time.

 

4.3.          Applications
for advances for direct construction costs shall also be signed by the general
contractor, if any, and shall be for amounts not exceeding the lesser of (i)
the cost of the completed construction and materials incorporated in the
improvements, and (ii) the maximum amount allocated thereto on the Loan
Budget.  Payment of each such
application will be subject to the certification of Lender’s inspector, based
on a physical inspection, that the work for which payment is requested has been
completed in accordance with the Plans and Specifications, that the cost
thereof is as set forth in the application, and that the work is progressing
rapidly enough to meet the completion date set forth in Section 3 of this
Agreement.  However, approval and/or
payment of any application shall not constitute a waiver of Lender’s rights as
to any work or material which may be defective or which may fail to comply with
the Plans and Specifications or with the requirements of Section 3 of this
Agreement.

 

4.4.          Applications
for advances for indirect construction costs (such as interest, insurance
premiums and settlement expenses) will include such supporting information as
Lender may reasonably require.  Lender
may make disbursements from the “Interest Reserve” that is part of the Loan
Budget for interest due Lender during construction without further
authorization from Borrower, but Lender agrees to send notice of such
disbursement to Borrower.  Borrower
acknowledges that the “Interest Reserve” in the Loan Budget (i) may not be
sufficient to pay interest on the Loan throughout the entire term thereof and
(ii) may not, by reason of the operation of Sections 4.7.2 and 4.8.1 below, be
available to be drawn upon by Borrower at the time any payment of interest is
due under the Note, and in such event Borrower will be responsible to make
payments for interest on the Loan out of funds other than the proceeds of the
Loan.

 

4.5.          Intentionally
Omitted.

 

4.6.          Intentionally
Omitted.

 

4.7.          Notwithstanding
anything to the contrary contained in this Agreement:

 

4

 

4.7.1.       Lender shall have the right to apply any funds
which it agrees to advance hereunder to bring about the completion of the
Improvements and to payment of any settlement costs, taxes, special assessments
or any other charges which could be a lien on the Real Estate, or any interest
on the Loan, or any premium on any insurance policy affecting the Mortgaged
Property.

 

4.7.2.       Lender shall not be obligated to make any
advance to Borrower if, as a result of such advance, the amount outstanding
under the Note would exceed the lesser of (i) $16,000,000, or (ii) the
“residual commitment.”  The “residual
commitment” shall mean the difference between (x) $39,040,921 and (y) the
greater of (A) aggregate amount of all sums theretofore repaid on account of
principal of this Loan or (B) the product of the number of Lots theretofore
released from the lien of the Mortgage multiplied by $302,643 Lender shall not
be obligated to advance funds to commence the construction of any Dwelling on
the Real Estate unless, in Lender’s reasonable opinion, sufficient funds are
available to complete such Dwelling unit and all other dwelling units then
under construction; that is, that the advance or advances necessary to complete
such additional Dwelling and all other Dwellings then under construction, will
not cause the amount outstanding under the Note to exceed, at any time, the
lesser of (i) $16,000,000 or (ii) the “residual commitment.”

 

4.7.3.       Lender shall not advance funds for the
construction of any Building if, as a result of the construction of such
Building, there would then be (i) more than thirteen (13) “spec” Dwellings or
(ii) there would then be completed or under construction Buildings containing,
in the aggregate and inclusive of “spec” Dwellings, more than fifty (50)
Dwellings owned by Borrower.  Dwellings
that are completed and owned by Borrower or are under construction and, in
either situation, not subject to a “firm” agreement of sale (including all
model Dwellings) shall be deemed to be “spec” Dwellings.  For purposes of this Agreement, an agreement
of sale shall be deemed to be “firm” if (i) the purchaser has paid a cash
deposit of not less than 5% of the purchase price (unless the purchaser of the
Dwelling shall have applied for FHA financing, in which case the minimum
deposit may be 3% of the sale price) and (ii) all contingencies to the
purchaser’s obligation under the agreement of sale (other than a standard
mortgage contingency which does not condition the mortgage on the sale of any
other property by the purchaser and the requirement for performance of the
seller’s obligations) have been satisfied. 
Notwithstanding the foregoing, in addition to the Buildings Borrower may
have under construction at any time pursuant to the first sentence of this
Section 4.7.3 Borrower may have under construction at any time the foundations
for additional Buildings on the Real Estate provided that the maximum number of
such additional Building foundations that may be under construction at any time
pursuant to this Section 4.7.3 shall not exceed two (2), and Lender shall
advance Loan proceeds for the costs thereof to the extent Lender determines in
good faith that such costs are reasonable.

 

4.7.4.       Lender shall not be obligated to advance with
respect to any Dwelling funds for the hard costs of construction of such
Dwelling in excess of $171,500.

 

4.7.5.       Lender shall not advance more than $6,095,654
from the “Site Improvements” category of the Loan Budget until Borrower shall
have completed closings on the sale of twenty (20) Dwellings and caused the
subject Lots to be released from the lien of the Mortgage.

 

5

 

4.8.          The
Loan proceeds allocated in the Loan Budget to “Hard Costs”, “Interest Reserve”
and “Marketing and Overhead” will be advanced to Borrower as follows:

 

4.8.1.       Hard Costs: 
After the delivery to Lender of each “firm” agreement of sale for a
Dwelling, $171,500 shall be available to be drawn by Borrower on account of
“Hard Costs”.

 

4.8.2.       Interest Reserve:  After the delivery to Lender of each “firm” agreement of sale for
a Dwelling, $6,295 shall be available to be drawn from the Interest
Reserve.  Notwithstanding the foregoing,
up to $55,000 to pay interest on the Loan for the period ending three months
after the date of this Agreement shall be available to be drawn from the
Interest Reserve without regard to the delivery to Lender of any “firm” agreements
of sale for any Dwellings.

 

4.8.3.       Marketing and Overhead:  After the delivery to Lender of each “firm”
agreement of sale for a Dwelling, $25,000 shall be available to be drawn by
Borrower on account of “Marketing and Overhead”.

 

4.8.4.       If prior to the advance of all “Interest
Reserve” or “Marketing and Overhead” funds pursuant to Sections 4.8.2 and 4.8.3
any “firm” agreement of sale shall be terminated for any reason other than
closing under such agreement of sale, for purposes of this Section 4.8 and of
Section 4.7.3 above the Dwelling that was the subject of the terminated
agreement shall thereafter be considered a “spec” Dwelling until such time as
it again is subject to a “firm” agreement of sale.

 

4.8.5.       Advances requested pursuant to this Section 4.8
shall be subject to all of the other conditions to an advance contained in this
Agreement.

 

4.9.          If
at any time Lender, in the good faith exercise of business judgment, determines
that the funds hereby agreed to be advanced (or the undisbursed balance
thereof) are insufficient for the purpose of completing the Improvements or of
paying any of the aforesaid charges, or any other charge or expense which may
have been incurred or may be assumed by Lender in connection with this
Agreement, Borrower agrees to pay to Lender the amount of any such deficiency
promptly on demand, which Lender shall hold in an interest bearing
account.  Any such amounts shall be
disbursed for the purposes set forth herein before any disbursements are made
out of the undisbursed portion of the Loan.

 

4.10.        No advance shall be made with respect to any
structure that is part of the Improvements unless Borrower has delivered to
Lender a valid building permit for such structure, issued by the City of
Lambertville, and a valid water and sewer connection permit for each Dwelling.

 

4.11.        No advance shall be made if any person has
filed a Notice of Unpaid Balance and Right to File Lien against any portion of
the Mortgaged Property pursuant to the New Jersey Construction Lien Law, P.L.
1993, Chapter 318, nor shall any advance be made unless Lender’s title insurer
has endorsed Lender’s policy of title insurance to insure the

 

6

 

Mortgage as a first lien on the
Mortgaged Property in the amount of the aggregate of such advance and all prior
advances.

 

5.             Hazard and Liability Insurance.

 

Borrower shall furnish and maintain insurance as
required by the Mortgage.  So long as
this Agreement is in force the policies of fire insurance shall be in the “Builder’s
Risk Completed Value Non-Reporting” form. 
If the fire insurance policies shall be in the “Builder’s Risk” form, no
portion of the Improvements may be occupied unless Borrower’s insurer
acknowledges to Lender in writing that such insurance shall remain in effect,
notwithstanding the occupancy of the Improvements.  In addition to the foregoing, Borrower shall furnish Lender with
certificates of comprehensive public liability insurance and worker’s
compensation insurance, covering Borrower and the General Contractor, if any,
in such amounts and form and with such companies as may be satisfactory to
Lender in the exercise of reasonable business judgment.

 

6.             Borrower’s Warranties.

 

Borrower, as a material inducement to Lender to make
the Loan, represents and warrants that:

 

6.1.          There
is no litigation pending or threatened which would in any way affect any of the
following: title to the Mortgaged Property or any part thereof; the validity or
priority of the lien of the Mortgage; issuance or validity of any zoning
variance or other zoning or subdivision approval affecting the Mortgaged
Property; any building permit or certificate of occupancy which has been or is
to be issued in connection with the Mortgaged Property or any part thereof.

 

6.2.          Borrower
has obtained or will obtain a validly issued building permit and such other
permits as may be required by law for construction of the Improvements and all
appeal periods allowed with respect thereto have expired without any appeal
having been filed by any person; the Plans and Specifications are identical in
all respects to those on which a building permit for each structure has been
(or will be) issued; and the Mortgaged Property now complies, and upon
completion of the Improvements will comply, in all respects with all
requirements of law including those relating to building, zoning, subdivision
and environmental protection.

 

6.3.          No
part of the Mortgaged Property has been damaged or taken by, or is under cloud
of, eminent domain proceedings.

 

6.4.          The
Mortgaged Property is not now damaged or injured as a result of any fire,
explosion, accident, flood or other casualty.

 

6.5.          There
has been no material adverse change in the financial condition of Borrower or
the Guarantor since the date of the loan application previously submitted to
Lender.

 

7

 

6.6.          The
Loan does not violate any other contractual obligation of Borrower or the
Guarantor.

 

6.7.          The
Mortgaged Property has unqualified access to and from a public road.

 

6.8.          Electricity,
potable water and sewerage facilities and, if shown on the Plans and
Specifications, natural gas service are available at the Mortgaged Property and
are of sufficient capacity to service the Improvements.

 

6.9.          To
the best of Borrower’s knowledge, information and belief (i) no hazardous
substance pollutant or contaminant (as defined in Section 101 of the
Comprehensive Environmental Response, Compensation and Liability Act (CERCLA),
42 U.S.C. “9601, as amended by the Superfund Amendments and Reauthorization Act
of 1986, Pub.L.No. 99-499, 100 Stat. 1613 (1986), is present on the Mortgaged
Property, (ii) the primary operations of the business being conducted on the
Mortgaged Property are in compliance with the New Jersey Industrial Sites Recovery
Act, N.J.S.A. 131k:6 et  seq. (ISRA); and (iii) Borrower has not
been identified in any litigation, administrative proceedings or investigation
as a responsible party for any liability under the above referenced laws.  Borrower will not use, generate, treat,
store, dispose of, or otherwise introduce any hazardous substances, hazardous
waste, residual waste or solid waste 
(as defined above) pollutant, contaminant hazardous waste, residual
waste or solid waste (as defined above) into or on the Mortgaged Property in
violation of any applicable statute, law, ordinance rule or regulation and will
not cause, suffer, allow, or permit anyone else to do so.

 

Each request for an advance of proceeds of the Loan
hereafter made by Borrower shall constitute Borrower’s representation and
warranty that (i) the representations and warranties contained in this Article
are true and correct as of the date such request for an advance is made and
(ii) all proceeds of the Loan theretofore disbursed by Lender to pay for labor
and materials have been applied and paid in strict accordance with all prior
requests for advances.

 

7.             Fees and Expenses.

 

Upon execution of this Agreement, Borrower will pay
Lender a loan fee of $150,205.  No
portion of said fee or of any commitment fee heretofore paid to Lender shall be
refundable if the maturity date of the Note is accelerated or if Borrower makes
any voluntary prepayment of the Loan. 
In addition, Borrower will pay or cause to be paid all other fees and
charges incurred in the procuring and making of the Loan, including, without
limitation, fees and expenses relating to examination of title, title insurance
premiums, surveys, recording charges, appraisal fees, environmental study fees,
any applicable documentary, transfer, recording or other similar taxes,
Lender’s counsel’s fees and disbursements for the preparation of Loan
documentation and the closing of the Loan.

 

8.             No Third Party Beneficiaries.

 

The parties do not intend the benefits of this
Agreement to inure to any third party. 
Notwithstanding anything contained herein or in the Mortgage, Note or
any other document executed in connection with this transaction, or any conduct
or course of conduct by

 

8

 

either or both of the parties hereto, or their
respective affiliated companies, agents or employees, before or after signing
this Agreement or any of the other aforesaid documents, this Agreement shall
not be construed as creating any rights, claims or causes of action against Lender,
or any of its officers, agents or employees in favor of any prime contractor or
any other contractor, subcontractor, supplier of labor or materials or any of
their respective creditors, or any other person or entity other than Borrower.  Without limiting the generality of the
foregoing, advances made directly to any prime contractor or any other
contractor, subcontractor or supplier of labor and materials, shall not be
deemed a recognition by the Lender of a third-party beneficiary status of any
such person or entity.

 

9.             Mechanics’ Liens.

 

If any mechanic’s lien, Notice of Unpaid Balance and
Right to File Lien or security interest shall be filed against the Mortgaged
Property or any part thereof, or any interest therein, by reason of work,
labor, services or materials supplied or claimed to have been supplied, or any
municipal lien or other lien or encumbrance, other than the Mortgage, is
recorded or filed and is not discharged (or if security therefor satisfactory
to Lender has not been deposited with Lender) within thirty (30) days after the
filing or recording thereof, then Lender may, at its option, pay and discharge
said lien or encumbrance, in which case the sum which Lender shall have so paid
shall be considered as part of the advances then due or thereafter to become
due, as Lender may elect.

 

10.           Default.

 

The occurrence of any one or more of the following
shall, at the option of Lender, and upon written notice from Lender to
Borrower, constitute an “Event of Default” hereunder:

 

10.1.        A petition shall have been filed by Borrower
under any of the provisions of the Federal Bankruptcy Act, as amended, or any
other Federal or state insolvency or similar law; or such petition shall have
been filed against Borrower or a receiver shall have been appointed in a
debtor’s proceeding for Borrower, or any part of its property or assets, or for
the Mortgaged Property or any part thereof, and such petition or receivership
shall continue unstayed and in effect for a period of thirty (30) days;

 

10.2.        Borrower shall have made an assignment for the
benefit of its creditors;

 

10.3.        Any execution shall have been levied against
the Mortgaged Property or against any other property of Borrower and shall
continue unstayed and in effect for a period of ten (10) days;

 

10.4.        Work in the construction of the Improvements
shall have been discontinued for five consecutive business days for any reason
whatsoever, except strikes, weather, Acts of God or similar elements of force
majeure;

 

9

 

10.5.        Borrower shall have created any security
interest in favor of any party other than Lender in the Real Estate or in any
fixtures, machinery or equipment used or to be used in connection with the
Improvements, or purchased any of the aforesaid items on any conditional sale
basis;

 

10.6.        Borrower shall have failed to comply with any
requirements of any governmental authority concerning the Improvements within
such period as may be allowed by such governmental authority, after notice in
writing of such requirements shall have been given to Borrower but such failure
shall not constitute an Event of Default if Borrower shall have filed a timely
appeal from such requirement and diligently pursues such appeal and if
enforcement against the Mortgaged Property is stayed during the pendency of
such appeal, provided that in Lender’s reasonable judgment a subsequent denial
of such appeal following continued construction during the pendency of the
appeal will not materially adversely affect Borrower’s ability to complete the
Improvements as required by this Agreement;

 

10.7.        Borrower shall have failed to disclose to
Lender, upon demand, the names of all persons with whom Borrower has contracted
or intends to contract in connection with the construction of the Improvements
or the furnishing of any labor, materials or services in connection therewith;

 

10.8.        Borrower shall have made any material amendment
in any contract with any general contractor or architect engaged by Borrower or
failed to pursue promptly any remedy under any such contract in the event of
any material default by the other party thereto;

 

10.9.        Borrower shall have failed to observe and
perform each and every one of the terms, covenants, promises and agreements on
its part to be observed and performed under this Agreement and such failure
shall continue for a period of ten (10) days after written notice from Lender
(but if such failure is susceptible to being cured but cannot be cured within
such 10 day period, such shall not be an Event of Default if Borrower shall
commence such cure within such 10 day period and diligently pursue such cure to
its completion) or any representation or warranty made by Borrower shall appear
to have been false or incorrect in any material respect when made;

 

10.10.      The occurrence of any “Event of Default” as
defined in the Note or the Mortgage;

 

10.11.      Borrower shall be in default, after the
expiration of any applicable grace period contained therein, under the terms of
any note, mortgage or other agreement with Lender, whether entered into before
or after the execution of this Agreement; and

 

10.12.      Borrower shall have entered into any written or
oral lease for any part of the Mortgaged Property without the prior written
consent of Lender.

 

For purposes of clauses Sections 10.1, 10.2, 10.3 and
10.11 above, the word “Borrower” shall include Borrower and the Guarantor.

 

10

 

11.           Remedies.

 

11.1.        Upon the occurrence of any Event of Default,
Lender may exercise any or all of the following rights and remedies as it may
deem necessary or appropriate:

 

11.1.1.     Declare immediately due and payable all sums
advanced under the Note which are then unpaid, with all accrued interest.

 

11.1.2.     Take possession of the Mortgaged Property and all
materials, supplies, tools, equipment and construction facilities and
appliances located thereon, and proceed either in the name of Lender or in the
name of Borrower as Lender shall elect, to complete the Improvements at the
cost and expense of Borrower (subject to Lender’s right to discontinue work at
any time).  If Lender elects to complete
or cause the Improvements to be so completed, Lender will not assume any
liability or be liable to Borrower or to any other person for completing the
Improvements or for the manner or quality of construction, and Borrower
expressly waives any such liability.  If
Lender elects to complete or cause the Improvements to be so completed, it may
do so according to the Plans and Specifications or according to such changes,
alterations or modifications in and to the Plans and Specifications as Lender
may deem expedient or necessary, and Lender may enforce or cancel all existing
contracts pertaining to the construction or make other contracts which in
Lender’s opinion may seem advisable, and Borrower shall pay or cause to be paid
Lender upon demand any amount or amounts expended by Lender for such
performance, together with any other costs, charges or expenses incident
thereto or otherwise incurred or expended by Lender in connection with the
Improvements, and the amount so expended shall bear interest at the applicable
rate provided in the Note and shall be considered part of the indebtedness
evidenced by the Note and secured by the Mortgage, regardless of whether such expenditures
cause Borrower’s indebtedness to Lender to exceed the face amount of the
Note.  For the purpose of securing
Borrower’s obligations hereunder, Borrower hereby assigns, transfers and sets
over to Lender all of Borrower’s right, title and interest in, to and under (i)
the Plans and Specifications, and (ii) all building and other permits issued by
any municipal authority with respect to the Improvements (whether heretofore or
hereafter issued); provided that Lender shall not exercise its rights under the
aforesaid assignment until default by Borrower hereunder.

 

11.1.3.     Refrain from making any one or more disbursements
of Loan proceeds which Borrower would otherwise be entitled to have made
hereunder.

 

11.2.        In any action or proceeding for recovery of any
sums expended by Lender in connection with the completion of the Improvements,
a statement of such expenditures, verified by the affidavit of an officer of
Lender, shall be prima facie evidence of the amounts so expended and of the
propriety of and necessity for such expenditures, and the burden of proving the
contrary shall be upon Borrower.

 

11.3.        The remedies provided in this Agreement shall
be in addition to and not in substitution for the rights and remedies which
would otherwise be vested in Lender under the Note and Mortgage or otherwise at
law or in equity, all of which rights and remedies are specifically reserved by
Lender.  Failure of Lender to exercise
any remedy shall not constitute a waiver of Lender’s rights for that default
nor for any further or future default.

 

11

 

11.4.        Borrower agrees that all property of Borrower
which may hereafter be deposited with or come into the possession of Lender
shall be applicable to secure the payment of the indebtedness evidenced by the
Note, and for this purpose Lender is hereby given a lien on and a security
interest in all thereof, and for such purpose this Agreement shall constitute a
security agreement under the Uniform Commercial Code.

 

12.           Notices.

 

All notices to be given by either party to the other
hereunder shall be in writing, shall be addressed to Borrower at its offices,
as hereinabove set forth, and to Lender at its office, as hereinabove set forth
(attention: Commercial Real Estate Department), and shall be delivered by
either an independent courier service that obtains a receipt for delivery or
certified or registered U.S. Postal Service mail, return receipt
requested.  Either party may change its
address for notices by written notice to the other party as aforesaid.

 

13.           Indemnity.

 

Borrower agrees to protect, indemnify, defend and save
harmless Lender and its directors, officers, agents and employees from and
against any and all loss, liability, and expense (including reasonable counsel
fees) arising out of disputes between Borrower and any contractor, or between
any contractor and any subcontractor, materialman or supplier, or between
Borrower or any contractor or any subcontractor and any municipal or public
authority, or between Borrower and any broker pertaining to this transaction.

 

14.           Minimum Sales Covenant.

 

Borrower covenants that Borrower shall obtain “firm”
agreements of sale (as defined in Section 4.7.3 above) for no fewer than seven
(7) Dwellings during each period of three (3) consecutive calendar months that
begins with any month of March, June, September or December, during the term of
the Loan, and for no fewer than fifteen (15) Dwellings during each period of
six (6) consecutive calendar months that begins with any month of March or
September, in each case beginning with the month of March, 2004.

 

15.           Sales and Releases.

 

15.1.        Borrower shall deliver to Lender, on or before
the 10th day of each month, a written statement setting forth all agreements of
sale then in effect with respect to the Mortgaged Property, in such detail as
Lender may in good faith require, including without limitation, a report on the
current status of all agreements of sale reported on prior statements.

 

15.2.        Lender agrees to release Lots from the lien of
the Mortgage in accordance with the provisions of Section 19 of the
Mortgage.  The “release price” for each
Lot shall be equal to (i) 100% of the hard costs of construction advanced for
such Lot, plus (ii) $144,257.

 

12

 

16.           Conflicts Between Instruments.

 

In the event of any conflict between the provisions of
this Construction Loan Agreement and the provisions of the Note, Mortgage or
any other document executed and/or delivered in connection with the Loan (including,
without limitation any provisions with respect to the delivery of notice of
default and the granting of any opportunity to cure) the provisions of this
Agreement shall prevail, notwithstanding any provision in any other document to
the effect that such other document shall be deemed controlling.  Any default by Borrower hereunder shall,
after the granting of such notice and expiration of any grace period as may be
herein contained, constitute an event of default under the Note and Mortgage,
without regard for any requirement for notice or opportunity to cure contained
in the Note or Mortgage.

 

17.           Parties Bound - Assignment.

 

This Agreement shall be binding upon the parties
hereto and upon their respective successors and assigns, and shall inure to the
benefit of the successors and assigns of Lender; provided, Borrower shall not
voluntarily, involuntarily, or by operation of law assign or transfer any
interest which it may have under this Agreement.

 

18.           Number and Gender.

 

For purposes of this Agreement the neuter shall be
deemed to include the masculine and the feminine, and the singular shall be
deemed to include the plural and the plural the singular, as the context may
require.

 

19.           Captions.

 

The captions contained herein are not a part of this
Agreement.  They are only for the
convenience of the parties and do not in any way modify, amplify, or give full
notice of any of the terms, covenants or conditions of this Agreement.

 

20.           Governing Law.

 

This Agreement shall be governed by and construed in
accordance with the laws of the Commonwealth of Pennsylvania.

 

21.           Waiver of Jury Trial.

 

BORROWER AND LENDER, AFTER CONSULTATION WITH THEIR
RESPECTIVE COUNSEL, EACH HEREBY WAIVE ANY RIGHT WHICH THEY MAY HAVE TO A JURY
TRIAL IN CONNECTION WITH ANY SUIT COMMENCED BY OR AGAINST THEM IN CONNECTION
WITH THIS AGREEMENT OR WITH ANY DOCUMENT EXECUTED IN CONNECTION WITH THIS
AGREEMENT OR THE LOAN, OR IN ANY WAY PERTAINING TO THE LOAN.

 

13

 

22.           Consent to Jurisdiction and Venue.

 

IN ANY LEGAL PROCEEDING INVOLVING, DIRECTLY OR
INDIRECTLY, ANY MATTER ARISING OUT OF OR RELATED TO THIS AGREEMENT OR THE
RELATIONSHIP EVIDENCED HEREBY, BORROWER HEREBY IRREVOCABLY SUBMITS TO THE
NONEXCLUSIVE JURISDICTION OF ANY STATE OR FEDERAL COURT LOCATED IN ANY COUNTY
IN THE COMMONWEALTH OF PENNSYLVANIA WHERE LENDER MAINTAINS AN OFFICE AND AGREES
NOT TO RAISE ANY OBJECTION TO SUCH JURISDICTION OR TO THE LAYING OR MAINTAINING
OF THE VENUE OF ANY SUCH PROCEEDING IN SUCH COUNTY.  BORROWER AGREES THAT SERVICE OF PROCESS IN ANY SUCH PROCEEDING
MAY BE DULY EFFECTED UPON IT BY MAILING A COPY THEREOF, BY REGISTERED MAIL,
POSTAGE PREPAID, TO BORROWER.

 

23.           Time of the Essence.

 

Time shall be the essence of this Agreement.

 

24.           Relationship of Parties.

 

The relationship between Borrower and Lender shall at
all times be that of debtor and creditor. 
Under no circumstances shall such relationship be construed as creating
a partnership or joint venture between Borrower and Lender.

 

25.           Severability.

 

Any provision of this Agreement which is prohibited or
unenforceable shall be ineffective to the extent of such prohibition or
unenforceability but shall not invalidate or render unenforceable any other
provision of this document and the remaining provisions shall stay in full
force and effect.

 

26.           Entire Agreement; Amendments.

 

This Agreement and the documents referred to herein
constitute the entire agreement and understandings between Borrower and Lender
with respect to the Loan.  All prior
negotiations, correspondence and discussions between Borrower and Lender and
their respective employees, partners, officers, agents and representatives with
respect to the Loan and the Mortgaged Property are merged into this Agreement
and shall have no force or effect.  This
Agreement may be amended only by a writing signed by the parties hereto.

 

27.           No Implied Waiver.

 

Lender shall not be deemed to have modified or waived
any of its rights or remedies hereunder unless such modification or waiver is
in writing and signed by Lender, and then only to the extent specifically set
forth therein.  A waiver in one event
shall not be construed as continuing or as a waiver of or bar to such right or
remedy in a subsequent event.  After any
acceleration of, or the entry of any judgment on, this Agreement, the
acceptance by Lender of any payments by or on behalf of Maker on account of the
indebtedness evidenced by this Agreement

 

14

 

shall not cure or be deemed to cure any Event of
Default or reinstate or be deemed to reinstate the terms of this Agreement
absent an express written agreement duly executed by Lender and Maker.

 

IN WITNESS WHEREOF, the parties hereto have hereunto
set their respective hands and seals the day and year first above written.

 

	
   

  	
  WACHOVIA BANK,
  NATIONAL ASSOCIATION

  
	
   

  	
   

  
	
    

  	
  By:

  	
  Julie A. Pasceri

  	
   

  
	
   

  	
   

  	
  Julie A.
  Pasceri,

  
	
   

  	
   

  	
  Assistant Vice
  President

  
	
   

  	
   

  
	
   

  	
   

  
	
   

  	
  ORLEANS AT LAMBERTVILLE, LLC, a

  New Jersey limited liability company

  
	
   

  	
   

  
	
   

  	
  By:

  	
  OHI NJ, Inc., a New
  Jersey corporation, its

  sole Managing Member

  
	
   

  	
   

  	
   

  
	
   

  	
  By:

  	
  Joseph A. Santangelo

  	
   

  
	
   

  	
   

  	
  Joseph A. Santangelo

  
	
   

  	
   

  	
  Vice President

  

 

15Exhibit
10.10

 

Bank of America, N.A.

 

PROMISSORY
NOTE

(Revolving Line of Credit)

 

	
  $17,500,000.00

  	
   

  	
  Richmond, Virginia

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
  March 9, 2000

  

 

FOR
VALUE RECEIVED, the undersigned, jointly and severally if more than one
(sometimes hereinafter referred to as the “undersigned” or the “Borrower”),
unconditionally promises to pay to the order of Bank of America, NA., a
national banking association or any subsequent holder of this note (the “Bank”)
at any of its offices in the Commonwealth of Virginia (or at such other place
or places as Bank may designate) the principal sum of SEVENTEEN MILLION FIVE HUNDRED THOUSAND
AND 00/100 DOLLARS ($17,500,000.00) or so much thereof as may be
from time to time outstanding, plus interest thereon at the rate hereinafter
set forth, all in accordance with the terms and conditions of this Promissory
Note (the “Note”) and in accordance with the Master Loan Agreement of even date
herewith by and between Borrower and Bank (the “Loan Agreement”).

 

This
Note is secured by a Credit Line Deed of Trust dated April 10, 1990 originally
filed for record in the public records of the County of Chesterfield, Virginia;
the Deed of Trust and Security Agreement dated July 2, 1999 originally recorded
with the Register of Deeds for Union County, Monroe, North Carolina in Deed
Book 1276, at Page 308 and the subsequent recording of the Deed of Trust and
Security Agreement dated July 2, 1999 with the Register of Deeds for
Mecklenburg County, North Carolina in Deed Book 10629, at Page 402; and the
Deed of Trust and Security Agreement dated October 25, 1999 originally recorded
with the Register of Deeds for Wake County, North Carolina in Deed Book 008452,
at Page 01395, and the various amendments, extensions, modifications,
supplements, renewals and/or replacements thereto (the “Deeds of Trust”), the
Guaranty (the “Guaranty”) of J. Russell Parker, III and Barbara H. Parker (the
“Guarantors”), and other agreements by and between Borrower and Bank. The
defined term Deed of Trust shall also include additional Deeds of Trust and
Security Agreements that are anticipated to be executed by Borrower conveying
to Bank various parcels of real estate located in other jurisdictions in the
State of North Carolina to additionally and further secure this Note and one or
more First Mortgage and Security Agreements that are anticipated to be executed
by Borrower conveying to Bank various parcels of real estate located in
jurisdictions in the State of South Carolina to additionally and further secure
the Note. The Deed of Trust, Guaranty, and such other agreements are
hereinafter referred to collectively as the “Security Documents” and the loan
evidenced and secured thereby is hereinafter referred to as the “Loan.”  Terms used herein but not otherwise defined
hereunder are defined as set forth in the Security Documents or the Loan
Agreement.  Subject to the terms and
conditions of this Note and the Security Documents, Bank shall advance funds to
Borrower pursuant to the terms of the Loan Agreement, such that Borrower may
borrow, partially or wholly repay, and reborrow, on a revolving basis, up to a
maximum principal sum equal to the face amount of this Note at any one time
outstanding.

 

 

1.             Prime Rate.  For purposes hereof, “Prime Rate” means the
fluctuating rate of interest per annum established by Bank as its prime lending
rate in effect from time to time whether or not such rate shall be otherwise
published.  Such Prime Rate is
established by Bank as an index or base rate and may or may not at any time be
the best or lowest rate of interest offered by Bank.

 

2.             Interest.  The outstanding Loan principal balance shall
bear interest at a variable rate per annum equal to the Prime Rate plus
one-half of one percent (0.50%).  The
interest rate hereunder shall be adjusted daily in accordance with fluctuations
in the Prime Rate.  Interest shall be
computed on the basis of a daily amount of interest accruing on the daily
outstanding principal balance during a 360-day year multiplied by the actual
number of days the principal is outstanding during such applicable interest
period.

 

3.             Payment of Principal and
Interest.    Borrower shall pay the
interest accruing on the outstanding principal balance of this Note beginning
on the fifteenth (15’“) day of the first month following the date of the initial
principal advance under this Note and continuing on the fifteenth (15th) day of
each month thereafter through and including the Maturity Date (as defined
below). Borrower shall pay all principal advanced with respect to a particular
Unit on the date that is not more than twelve (12) months after the closing
date of the loan on such Unit. Borrower shall pay all principal advanced with
respect to a particular Lot on a date that is not more than nine (9) months
after the closing date of the loan on such Lot. Such principal advances shall
be recorded on the books and records of Bank, which books and records shall be
conclusive evidence of the principal amount advanced and outstanding on this
Note. All payments of principal and interest shall be made in lawful currency
of the United States of America which shall be legal tender in payment of all
debts, public and private, at the time of payment. If not sooner paid, the
entire outstanding balance of principal, interest, late charges and other costs
due and owing hereunder shall be due and payable in full on December 31, 2001
(the “Maturity Date”).

 

4.             Prepayment.          This Note may be prepaid in whole or
in part at any time without fee, premium or penalty. Any partial prepayment
shall be applied in accordance with paragraph 9 below and shall not postpone
the due date of any subsequent periodic installments or the Maturity Date, or
change the amount of such installments due, unless Bank shall otherwise agree
in writing.

 

5.             Late Charges.        Should Borrower fail to pay the
installments of interest or principal on any due date provided for herein or
within fifteen (15) days thereafter, then Borrower further promises to pay a
late payment charge equal to four percent (4%) of the amount of the unpaid
installment as liquidated compensation to Bank for the extra expense to Bank to
process and administer the late payment, Borrower agreeing, by execution
hereof, that any other measure of compensation for a late payment is
speculative and impossible to compute. This provision for late charges shall
not be deemed to extend the time for payment or be a “grace period” or “cure
period” that gives Borrower a right to cure a Default. Imposition of late
charges is not contingent upon the giving of any notice or lapse of any cure
period provided for in the Deed of Trust and shall not be deemed a waiver of
any right or remedy of Bank, including without limitation, acceleration of this
Note.

 

6.             Default.  A Default as defined in the Loan Agreement or
an event of default as defined in the Deed of Trust shall constitute a default
under this Note.

 

 

7.             Acceleration. Upon the
occurrence of a default hereunder, Bank may declare the then outstanding
principal and all accrued but unpaid interest immediately due and payable and
upon acceleration and thereafter this Note shall bear interest at the Default
Rate, hereinafter defined, until all indebtedness evidenced hereby and secured
by the Security Documents has been paid in full. Further, in the event of such
acceleration, the Loan, and all other indebtedness of Borrower to Bank arising
out of or in connection with the Loan shall become immediately due and payable,
without presentation, demand, protest or notice of any kind, all of which are
hereby waived by Borrower.

 

8.             Default Rate.         After default or maturity or upon
acceleration, and thereafter, the unpaid indebtedness then evidenced by this
Note and due under and secured by the Security Documents shall bear interest at
a rate equal to the rate otherwise provided for herein plus three percent (3.00%)
per annum.

 

9.             Application of Payments.   All sums received by Bank for application to
the Loan may be applied by Bank to late charges, expenses, costs, interest,
principal, and other amounts owing to Bank in connection with the Loan in the
order selected by Bank in its sole discretion.

 

10.           Expenses.              In the event this Note is not paid
when due on any stated or accelerated maturity date, or should it be necessary
for Bank to enforce any other of its rights under this Note, the Loan
Agreement, or the Security Documents, Borrower will pay to Bank, in addition to
principal, interest and other charges due hereunder or under the Loan Agreement
or the Security Documents, all costs of collection or enforcement, including
reasonable attorneys’ fees, plus costs and expenses, whether incurred with
respect to collection, litigation, bankruptcy proceedings, interpretation,
dispute, negotiation, trial, appeal, defense of actions instituted by a third
party against Bank arising out of or related to the Loan, enforcement of any
judgment based on this Note, or otherwise, whether or not a suit to collect
such amounts or to enforce such rights is brought or, if brought, is prosecuted
to judgment.

 

11.           Waiver. All persons now or at
any time liable for payment of this Note, whether directly or indirectly,
including without limitation any Guarantor, hereby waive (a) presentment,
demand, protest, notice of protest and dishonor, (b) all homestead or other
exemptions which may be available to them, and (c) any right which they may have
to require Bank to proceed against any other party liable for the payment of
this Note or against any property securing this Note. Borrower expressly
consents to any extensions and renewals, in whole or in part, to the release of
any or all Guarantors or co-makers and any collateral security or portions
thereof given to secure this Note, and all delays in time of payment or other
performance which Bank may grant, in its sole discretion, at any time and from
time to time without limitation, all without any notice to or further consent
of Borrower, and any such grant by Bank shall not be deemed a waiver of any
subsequent delay or any of Bank’s rights hereunder or under the Loan Agreement
or the Security Documents.

 

12.           Usury.    In no event shall any provision herein or in the Loan Agreement
or Security Documents permit the collection of any interest which would be
usurious under the laws of the Commonwealth of Virginia, the State of North
Carolina or the State of South Carolina, as applicable. If any such interest in
excess of the maximum rate allowable under applicable law has been collected,
Borrower agrees that the amount of interest collected above the maximum rate
permitted by applicable law shall be applied as a principal prepayment
hereunder.

 

 

13.           Modification.  This Note
may not be changed orally, but only by an agreement in writing signed by Bank
and Borrower.

 

14.           Applicable Law.   This Note shall be governed by and
interpreted in accordance with the laws of the Commonwealth of Virginia, the
State of North, Carolina or the State of South Carolina, as applicable,
regardless of the jurisdiction in which this Note is executed or intended to be
performed, or in which any party hereto maintains its principal place of
business. If this Note is not dated when executed by Borrower, Bank is hereby
authorized, without notice to Borrower, to date this Note as of the date when
any portion of the proceeds of the Loan evidenced hereby is first advanced.

 

15.           Successors and Assigns.   As used herein, the terms the “Borrower” and
the “Bank” shall be deemed to include their respective heirs, personal
representatives, successors and assigns.

 

16.           Severability. In the event any
one or more of the provisions of this Note shall for any reason be held to be
invalid, illegal, or unenforceable, in whole or in part or in any respect, or
in the event that any one or more of the provisions of this Note operates or
would prospectively operate to invalidate this Note, then and in any of those
events, only such provision or provisions shall be deemed null and void and
shall not affect any other provision of this Note. The remaining provisions of
this Note shall remain operative and in full force and effect and shall in no
way be affected, prejudiced, or disturbed thereby. In the event any provisions
of this Note are inconsistent with the provisions of the Loan Agreement, the
Security Documents, or any other agreements or documents executed in connection
with this Note, this Note shall control.

 

17.           Captions; Pronouns.           Captions are for reference only and
in no way limit the terms of this Note. 
The pronouns used in this instrument shall be construed as masculine,
feminine, or neuter as the occasion may require.  Use of the singular includes the plural, and vice versa.

 

18.           Business Day.      Any reference herein or in the Loan
Agreement or Security Documents to a day or business day shall be deemed to
refer to a banking day which shall be a day on which Bank is open for the
transaction of business, excluding any national holidays, and any performance
which would otherwise be required on a day other than a banking day shall be
timely performed in such instance, if performed on the next succeeding banking
day.  Notwithstanding such timely
performance, interest shall continue to accrue hereunder until such payment or
performance has been made.

 

19.           Mandatory Arbitration.      Any controversy or claim between or among
the parties hereto including, but not limited to, those arising out of or
relating to this Note or any related agreements or instruments, including any
claim based on or arising from an alleged tort, shall be determined by binding
arbitration in accordance with the Federal Arbitration Act (or if not
applicable, the applicable state law), the Rules of Practice and Procedure for
the Arbitration of Commercial Disputes of Judicial Arbitration and Mediation
Services, Inc. (J.A.M.S.), and the “Special Rules” set forth below. In the
event of any inconsistency, the Special Rules shall control. Judgment upon any
arbitration award may be entered in any court having jurisdiction. Any party to
this Note may bring an action, including a summary or expedited proceeding, to
compel arbitration of any controversy or claim to which this agreement applies
in any court having jurisdiction over such action.

 

 

(a)
Special Rules: The arbitration shall be conducted in the City of Richmond,
Virginia, and administered by J.A.M.S, who will appoint an arbitrator; if
J.A.M.S, is unable or legally precluded from administering the arbitration,
then the American Arbitration Association will serve. All arbitration hearings
will be commenced within 90 days of the demand for arbitration; further, the
arbitrator shall only, upon a showing of cause, be permitted to extend the
commencement of such hearing for up to an additional 60 days.

 

(b)
Reservations of Rights: Nothing in this Note shall be deemed to (i) limit the
applicability of any otherwise applicable statutes of limitation or repose and
any waivers contained in this Note; or (ii) be a waiver by Bank of the
protection afforded to it by 12 U.S.C. Section 91 or any substantially
equivalent state law; or (iii) limit the right of Bank (A) to exercise self
help remedies such as (but not limited to) setoff, or (B) to foreclose against
any real or personal property collateral, or (C) to obtain from a court
provisional or ancillary remedies such as (but not limited to) injunctive
relief or the appointment of a receiver. Bank may exercise such self help
rights, foreclose upon such property, or obtain such provisional or ancillary
remedies before, during or after the pendency of any arbitration proceeding
brought pursuant to this Note. At Bank’s option, foreclosure under a mortgage
or deed of trust may be accomplished by any of the following: the exercise of a
power of sale under the deed of trust, or by judicial sale under the deed of
trust, or by judicial foreclosure. Neither this exercise of self help remedies
nor the institution or, maintenance of an action for foreclosure or provisional
or ancillary remedies shall constitute a waiver of the right of any party,
including the claimant in any such action, to arbitrate the merits of the
controversy or claim occasioning resort to such remedies. No provision in any
of the documents evidencing, securing or relating to this Note regarding submission
to jurisdiction and/or venue in any court is intended or shall be construed to
be in derogation of the provisions herein for arbitration of any controversy or
claim.

 

20.           Participation or Sale of Loan.             Bank may sell the Loan or undivided
ownership or participation interests in the Loan to one or more assignees or
participants and is hereby authorized to disclose in confidence in the
negotiation or closing of any such transaction any information it has
pertaining to the Loan, including, without limitation, any security for this
Note and credit information regarding Borrower, any of its principals, and any
Guarantor of the Loan, to any such assignee or participant or prospective
assignee or prospective participant, as Bank deems necessary.  Borrower acknowledges the rights of Bank as
set forth in the preceding sentence and agrees to execute, acknowledge, and
deliver upon request (and cause any Guarantor to do likewise) any and all
instruments reasonably requested by Bank in connection with the foregoing.

 

21.           Notices. Unless specifically provided otherwise, any
notice to Borrower for the purposes of this Note or any other documents
executed in connection with this Note shall be given in writing or by facsimile
(fax) transmission and shall be addressed or delivered to the address set forth
following Borrower’s signature, or to such other address as may be subsequently
designated by the intended recipient by notice given in accordance with this
provision.  If sent by registered or
certified mail (return receipt requested), the notice shall be deemed effective
when the receipt is signed or when the attempted initial delivery is refused or
cannot be made because of a change of address of which the sending party has
not been notified; if sent in any other manner, the notice shall be effective
when received or when the attempted initial delivery is refused.  A copy of any notice sent by fax shall also
be sent by certified mail.

 

 

No
notice of change of address shall be effective except upon actual receipt.  This provision shall not be construed in any
way to affect or impair any waiver of notice or demand provided herein or in
any documents executed in connection with this Note or to require giving of
notice or demand to or upon any person in any situation or for any reason.

 

WITNESS
the following signatures and seals,

 

	
   

  	
  BORROWER:
  Parker & Lancaster Corporation

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
   

  	
  By:

  	
  J. Phillip Harris

  	
  (SEAL)

  
	
   

  	
   

  	
  J. Phillip Harris

  	
   

  
	
   

  	
   

  	
  Vice President

  	
   

  
	
   

  	
   

  	
   

  
	
   

  	
   

  	
   

  
	
   

  	
  The
  Address of Borrower is:

  	
   

  
	
   

  	
   

  	
   

  
	
   

  	
  711
  Moorefield Park Drive, Suite E

  	
   

  
	
   

  	
  Richmond,
  VA 23236

  	
   

  
	
   

  	
   

  	
   

  
	
   

  	
  Fax
  #: (804) 330-7198

  	
   

  
	
   

  	
  Tax
  ID #: 54-1201707

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00061-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00061-of-00352.parquet"}]]