Document:

Exhibit

Exhibit 10.40
THIS AGREEMENT AND DEED is dated 
PARTIES
		
	(1)
	NACCO Materials Handling Ltd, a company registered in accordance with the Companies Acts with company number 02636775 and having its registered office at Centennial House, Building 4.5, Frimley Business Park, Frimley, Surrey, GU16 7SG (Company).

		
	(2)
	Ralf Mock who, albeit working and residing in the UK, has a place of residence at Wiesbadenerstrasse.71, D-61462, Koenigstein, Germany  (Employee).

BACKGROUND
		
	(A)
	The Employee was employed by the Company under a UK employment contract and was based in the UK for the duration of his employment with the Company.

		
	(B)
	The Employee's employment with the Company terminated on 15 April 2015.

		
	(C)
	The parties have entered into this agreement to record and implement the terms on which they have agreed to settle any claims which the Employee has or may have in connection with his employment or its termination or otherwise against the Company or its officers or employees whether or not those claims are, or could be, in the contemplation of the parties at the time of signing this agreement, and including, in particular, the statutory complaints which the Employee raises in this agreement. It is the parties' intention that each Affiliate should be able to enforce any rights it has under this agreement, subject to and in accordance with the Contracts (Rights of Third Parties) Act 1999.

		
	(D)
	The parties intend this agreement to be an effective waiver of any such claims and to satisfy the conditions relating to settlement agreements and compromise contracts in the relevant legislation.

AGREED TERMS
		
	1.
	INTERPRETATION

The following definitions and rules of interpretation apply in this agreement.
		
	1.1
	Definitions:

Adviser: Frank Ryan of Barker Gillette LLP, 11 – 12 Wigmore Place, London, W1U 2LU.
Affiliates: the following organisations including any of their officers, directors or employees: NACCO Materials Handling France SA, NACCO Materials Handling B.V., Hyster Germany GmbH, Hyster France S.A.R.L., Hyster-Yale Materials Handling GmbH, Hyster-Yale Materials Handling, Inc, Yale France Manutention S.A.R.L., NACCO Materials Handling S.p.A., Yale Materials Handling (UK) Limited and/or NACCO Materials Handling Group, Inc.
Board: the board of directors of the Company (including any committee of the board duly appointed by it).
Confidential Information: information in whatever form (including, without limitation, in written, oral, visual or electronic form or on any magnetic or optical disk or memory and wherever located) relating to the business, products, affairs and finances of the Company for the time 

being confidential to the Company and trade secrets including, without limitation, technical data and know-how relating to the business of the Company or any of its suppliers, clients, customers, agents, distributors, shareholders or management, including (but not limited to) information that the Employee created, developed, received or obtained in connection with his employment, whether or not such information (if in anything other than oral form) is marked confidential.
Copies: copies or records of any Confidential Information in whatever form (including, without limitation, in written, oral, visual or electronic form or on any magnetic or optical disk or memory and wherever located) including, without limitation, extracts, analysis, studies, plans, compilations or any other way of representing or recording and recalling information which contains, reflects or is derived or generated from Confidential Information.
		
	1.2
	The headings in this agreement are inserted for convenience only and shall not affect its construction.

		
	1.3
	A reference to a particular law is a reference to it as it is in force for the time being taking account of any amendment, extension, or re-enactment and includes any subordinate legislation for the time being in force made under it.

		
	1.4
	Unless the context otherwise requires, a reference to one gender shall include a reference to the other genders.

		
	1.5
	Unless the context otherwise requires, words in the singular shall include the plural and in the plural shall include the singular.

		
	1.6
	The Schedules form part of this agreement and shall have effect as if set out in full in the body of this agreement. Any reference to this agreement includes the Schedules.

		
	2.
	ARRANGEMENTS ON TERMINATION

		
	2.1
	The Employee's employment with the Company terminated on 15 April 2015. (Termination Date).

		
	2.2
	The Company has paid the Employee his salary up to the Termination Date in the usual way.

		
	2.3
	The Company has provided benefits to the Employee in the usual way up to the Termination Date.

		
	2.4
	The Company shall continue to fund private healthcare cover and life assurance for the Employee which, where reasonably practicable, will be subject to the same terms and conditions and on the same basis as applied immediately prior to the Termination Date or on terms and conditions which are as similar as reasonably possible, for the period from the Termination Date up to and including 14 April 2016.

		
	2.5
	The Company shall deduct from the Termination Payment due to the Employee under this agreement any outstanding sums due from the Employee to the Company including the sum of £5,048.78 in respect of  annual leave taken by the Employee beyond the entitlement he had accrued at the Termination Date. 

		
	2.6
	The payments and benefits in this clause 2 shall be subject to the income tax and National Insurance contributions that the Company is obliged by law to pay or deduct.

		
	2.7
	The Employee shall submit on or before 31 July 2015 his expenses claims in the usual way and the Company shall reimburse the Employee for any expenses properly incurred before the Termination Date in the usual way. Any expenditure on his Company credit card which was not properly incurred by him on the Company's business or for which he cannot produce appropriate receipts will be deducted from the payments due under this agreement.

		
	3.
	TERMINATION PAYMENT

		
	3.1
	Subject to and conditional on the Employee complying with the terms of this agreement, the Company shall within 14 days of the later of: 1)  receipt by the Company of a copy of this agreement signed by the Employee together with a signed letter from the Adviser as set out in Schedule 3 and signed letters from the Employee set out in Schedule 4; and 2) 1 August 2015:

(A) pay to the trustees of the pension scheme for the benefit of the Employee the sum of £39,917 as compensation in lieu of 12 months’ employer pension contributions and at the same time send to the Employee evidence of the payment having been so sent; and 
(B) pay to the Employee by way of compensation for the termination of his employment £573,250, (Termination Payment) consisting of:
		
	(a)
	Compensation in lieu of notice of £410,454 comprising:

		
	(i)
	£291,711 as compensation in lieu of 12 months’ salary; 

		
	(ii)
	£13,326 as compensation in lieu of 12 months’ car allowance;

		
	(iii)
	 £42,356 compensation in lieu of any expected payments under the Annual Incentive Plan; and

		
	(iv)
	£63,061 compensation in lieu of any expected payments under the 2015 Long Term Incentive Plan.

and
		
	(b)
	£162,796 as compensation for loss of office.

		
	3.2
	The Company and the Employee believe that the payment in clause 3.1(A) and the first £30,000 of the payment in clause 3.1(B) will be tax free. The Company shall deduct income tax and National Insurance contributions from the remainder of the Termination Payment and the payments in clauses 3.3 and 12.6 at the appropriate rate. The Employee shall be responsible for any further tax and employee's National Insurance contributions which are due or become in respect of the Termination Payment and the payments in clauses 3.3 and 12.6 and shall indemnify the Company in respect of such liability in accordance with clause 7. 

		
	3.3
	The Company shall pay the Employee’s vested entitlement under the Long Term Incentive Plan for years 2012, 2013 and 2014, which amounts are detailed below and will be paid as follows, subject to deductions of tax and National Insurance contributions.  (For the avoidance of doubt 

the amounts below include all interest entitlement and no further interest will accrue from the Termination Date.):
		
	(a)
	US$271,370.46 in respect of 2012 will be paid before the end of March 2016;

		
	(b)
	US$320,489.46 in respect of 2013 will be paid before the end of March 2017; and

		
	(c)
	US$128,923.00 in respect of 2014 will be paid before the end of March 2018.

		
	3.4
	It is agreed that, in respect of the Termination Payment and the payment in clause 12.6, the Company shall apply tax code OT and “the appropriate rate” for deductions of tax and National Insurance contributions referred to in clause 3.2 shall be as follows:

		
	(a)
	the first £30,000 of the Termination Payment shall be paid without deductions for tax and National Insurance contributions with the remainder of the Termination Payment subject to deductions of tax only;

		
	(b)
	the payment at clause 12.6 shall be paid after deductions of tax and National Insurance contributions;

		
	(c)
	tax will be deducted from [the remainder of the Termination Payment referred to in clause 3.4 (a) less deduction of the sums at clause 2.5 plus the payment in clause 12.6] as follows:

		
	(i)
	the first £2,648.75 shall be taxed at 20%

		
	(ii)
	the following £9,851.25 shall be taxed at 40%; and

		
	(iii)
	the remaining sum shall be taxed at 45%.

		
	(d)
	National Insurance contributions shall be deducted from the payment set out in clause 12.6 as follows:

		
	(i)
	£0 to £672 at 0%;

		
	(ii)
	£673 to £3,531 at 12%; and

		
	(iii)
	the remaining £16,469 at 2%.

		
	3.5
	Should the Company become aware, before making payment to the Employee, of any obligation on its part to deduct tax and/or National Insurance contributions in respect of the payment in clause 3.1(A) it shall make such deductions of tax and National Insurance contributions as it is required by law to make before making payment to the Employee. 

		
	4.
	PENSION

The Company shall notify the trustees of the pension scheme that the Employee's employment has been terminated and request written confirmation of the Employee's accrued entitlement under the Pension Scheme and request that the options available for dealing with his entitlement are sent to the Employee.
		
	5.
	LEGAL FEES

The Company shall pay a contribution of £14,300 plus VAT to the legal fees incurred by the Employee in obtaining advice on the termination of his employment and the terms of this 

agreement, such fees to be payable to the Adviser on production of an invoice addressed to the Employee and marked payable by the Employer, such invoice to be sent by the Adviser to John Short c/o Andrew Brown, Anderson Strathern LLP, 1 Rutland Court, Edinburgh, EH3 8EY.
		
	6.
	WAIVER OF CLAIMS

		
	6.1
	The Employee agrees that the terms of this agreement are offered by the Company without any admission of liability on the part of the Company and are in full and final settlement of all and any claims or rights of action that the Employee has or may have against the Company or its officers or employees whether arising out of his employment with the Company or its termination or from events occurring after this agreement has been entered into, whether under common law, contract, statute or otherwise, whether such claims are, or could be, known to the parties or in their contemplation at the date of this agreement in any jurisdiction and including, but not limited to, the claims specified in Schedule 2 (each of which is hereby intimated and waived).

		
	6.2
	The waiver in clause 6.1 shall not apply to the following:

		
	(a)
	any claims by the Employee to enforce this agreement;

		
	(b)
	claims in respect of personal injury of which the Employee is not aware and could not reasonably be expected to be aware at the date of this agreement; and

		
	(c)
	any claims in relation to accrued entitlements under the pension scheme.

		
	6.3
	The Employee warrants that:

		
	(a)
	before entering into this agreement he received independent advice from the Adviser as to the terms and effect of this agreement and, in particular, on its effect on his ability to pursue any complaint before an employment tribunal or other court;

		
	(b)
	the Adviser has confirmed to the Employee that they are a solicitor holding a current practising certificate and that there is in force a policy of insurance covering the risk of a claim by the Employee in respect of any loss arising in consequence of their advice;

		
	(c)
	the Adviser shall sign and deliver to the Company a letter in the form attached as Schedule 3 to this agreement;

		
	(d)
	before receiving the advice the Employee disclosed to the Adviser all facts and circumstances that may give rise to a claim by the Employee against the Company or its officers or employees;

		
	(e)
	the only claims that the Employee has or may have against the Company or its officers or employees (whether at the time of entering into this agreement or in the future) relating to his employment with the Company or its termination are specified in clause 6.1; and.

		
	(f)
	the Employee is not aware of any facts or circumstances that may give rise to any claim against the Company or its officers or employees other than those claims specified in clause 6.1.

The Employee acknowledges that the Company acted in reliance on these warranties when entering into this agreement.
		
	6.4
	The Employee acknowledges that the conditions relating to settlement agreements and compromise contracts under all and any relevant legislation, including but not limited to section 203(3) of the Employment Rights Act 1996 and regulation 35(3) of the Working Time Regulations 1998 have been satisfied.

		
	6.5
	The waiver in clause 6.1 shall have effect irrespective of whether or not, at the date of this agreement, the Employee is or could be aware of such claims or have such claims in his express contemplation (including such claims of which the Employee becomes aware after the date of this agreement in whole or in part as a result of new legislation or the development of common law or equity).

		
	6.6
	The Employee agrees that, except for the payments and benefits provided for in this agreement including those outlined in clause 3.3, and subject to the waiver in clause 6.1, he shall not be eligible for any further payment from the Company relating to his employment or its termination and without limitation to the generality of the foregoing, he expressly waives any right or claim that he has or may have to payment of bonuses, any benefit or award programme or grant of equity interest, or to any other benefit, payment or award he may have received had his employment not terminated.

		
	7.
	EMPLOYEE INDEMNITIES

		
	7.1
	The Employee shall indemnify the Company on a continuing basis in respect of any income tax or National Insurance contributions (save for employers' National Insurance contributions) due in respect of the payments and benefits included in this agreement (and any related interest, penalties, costs and expenses save such as are incurred solely as a result of the Company’s default or delay in complying with its obligations to or responding to HM Revenue and Customs or other competent body). The Company shall give the Employee reasonable notice of any demand for tax which may lead to liabilities on the Employee under this indemnity and shall provide him with reasonable access to any documentation he may reasonably require to dispute such a claim (provided that nothing in this clause shall prevent the Company from complying with its legal obligations with regard to HM Revenue and Customs or other competent body).

		
	7.2
	If the Employee breaches any material provision of this agreement or pursues a claim against the Company other than those preserved  under clause 6.2, he agrees to: (i) immediately repay to the Company the Termination Payment (which shall be recoverable as a debt); and (ii) indemnify the Company for any losses suffered as a result thereof, including all reasonable legal and professional fees incurred in defending or resolving the claim.

		
	8.
	COMPANY PROPERTY AND INFORMATION

		
	8.1
	The Employee shall, before 31 July 2015, return to John Short, Vice President Human Resources, EMEA, Centennial House, Building 4.5, Frimley Business Park, Frimley, Surrey, GU16 7SG:

		
	(a)
	all Confidential Information and Copies;

		
	(b)
	all property belonging to the Company in satisfactory condition including (but not limited to) any car (together with the keys and all documentation relating to the car), fuel card, company credit card, keys, security pass, identity badge, mobile telephone, pager, lap-top computer or fax machine; and

		
	(c)
	all documents and copies (whether written, printed, electronic, recorded or otherwise and wherever located) made, compiled or acquired by him during his employment with the Company or relating to the business or affairs of the Company or its business contacts,

in the Employee's possession or under his control.
		
	8.2
	The Employee shall, before 31 July 2015, erase irretrievably any information relating to the business or affairs of the Affiliates or the Company or its or their business contacts from computer and communications systems and devices owned or used by him outside the premises of the Company, including such systems and data storage services provided by third parties (to the extent technically practicable).

		
	8.3
	The Employee shall, by 31 July 2015, provide a signed statement that he has complied fully with his obligations under clause 8.1 and clause 8.2 and, within 14 days of a request to do so, shall provide the Board with such reasonable evidence of compliance as may be requested.

		
	9.
	EMPLOYEE WARRANTIES AND ACKNOWLEDGMENTS

		
	9.1
	As at the date of this agreement, the Employee warrants and represents to the Company that there are no circumstances of which the Employee is aware or of which the Employee ought reasonably to be aware which would amount to a repudiatory breach by the Employee of any express or implied term of the Employee's contract of employment which would entitle (or would have entitled) the Company to terminate the Employee's employment without notice or payment in lieu of notice and any payment to the Employee pursuant to clause 3  is conditional on this being so.

		
	9.2
	As at the date of this agreement, the Employee warrants and represents to the Company that he has not received or accepted and does not expect to receive or accept any particular offer which will provide him with any form of income or benefits at any time after the Termination Date and any payment to the Employee pursuant to clause 3 is conditional on this being so.

		
	9.3
	As at the date of this agreement, the Employee warrants and represents to the Company that there are no circumstances which might require the Company to deduct more tax or National Insurance contributions than as set out in clauses 3.2 and 3.4 including in relation to any annual or lifetime allowances in respect of pension contributions.

		
	9.4
	The Employee agrees to make himself available to, and to cooperate with, the Company and/or its advisers in any internal investigation or administrative, regulatory, judicial or quasi-judicial proceedings. The Employee acknowledges that this could involve, but is not limited to, responding to or defending any regulatory or legal process, providing information in relation to 

any such process, preparing witness statements and giving evidence in person on behalf of the Company. The Company shall reimburse any reasonable expenses incurred by the Employee as a consequence of complying with his obligations under this clause, provided that such expenses are approved in advance by the Company.
		
	9.5
	The Employee acknowledges that he is not entitled to any compensation for the loss of any rights or benefits under any share option, bonus, long-term incentive plan or other profit sharing scheme operated by the Company in which he may have participated other than the payments in clause 3, including but not limited to the Long Term Incentive Plan or the Annual Incentive Plan, and hereby waives and settles any other such rights.

		
	10.
	REFERENCE

On receipt of a written request from a potential employer addressed to John Short, Vice President Human Resources EMEA, NACCO Materials Handling Ltd, Centennial House, Building 4.5, Frimley Business Park, Frimley, Surrey GU16 7SG, the Company shall provide a reference in the form set out in Schedule 1 to this agreement and any oral reference provided will be on no less favourable terms providing the request is directed to John Short. If the Company obtains information after the date of this agreement which would have affected its decision to provide a reference in the form in Schedule 1, it shall advise the Employee by email to mockralf@aol.com of such information and seek his observations on that information.  If the Employee fails to provide his observations to the Company within 14 days of being requested to do so or the Company reasonably concludes after reviewing the Employee’s observations that it should decline to provide a reference in the form in Schedule 1 it shall advise the Employee by email of that fact and of its reasons for so concluding.
		
	11.
	RESIGNATION FROM OFFICES

		
	11.1
	The Employee hereby acknowledges that he is no longer a Director of NACCO Materials Handling France SA and Hyster-Yale Materials Handling GmbH and hereby resigns as a Director of the Company and from his positions as:

		
	(a)
	Supervisory Board Member, NACCO Materials Handling B.V. 

		
	(b)
	Director, Yale Materials Handling UK Limited.

		
	(c)
	Director, NACCO Materials Handling SpA (Italy).

and any other office, trusteeship or position that he holds in or on behalf of the Company or in connection with his employment. 
		
	11.2
	The Employee irrevocably appoints the Company to be his attorney in his name and on his behalf to sign, execute or do any such instrument or thing and generally to use his name in order to give the Company (or its nominee, including any of the organisations listed in this clause) the full benefit of the provisions of this clause.

		
	11.3
	The Employee shall deliver to John Short a fully signed and completed copy of each of the letters in the form set out at Schedule 4 on or before 31 July 2015 and any other such document as the Company may reasonably require him to provide to effect his resignation from any office, 

trusteeship or position which he holds on behalf of the Company or in connection with his employment.
		
	11.4
	The Employee hereby acknowledges and confirms that he has no claim or right of action of any kind for compensation or otherwise against the Company or any of the organisations listed above or any of its or their officers or employees in respect of the termination of his office or otherwise. To the extent that any such claim or right of action exists or may exist, he irrevocably waives such claim or right of action and releases and forever discharges the Company, each of the organisations listed above, its and their officers and employees from all and any liability in respect thereof.

		
	11.5
	The Company hereby agrees to maintain, and to procure that the organisations detailed in this clause maintain appropriate Director’s and Officer’s Liability Insurance cover in respect of residual liabilities for the acts and omissions of the Employee on equivalent terms to those applying to the remaining Directors.

		
	12.
	CONFIDENTIALITY 

		
	12.1
	The Employee acknowledges that, as a result of his employment, he has had access to Confidential Information. Without prejudice to his common law duties, the Employee shall not (except as authorised or required by law or as authorised by the Company) at any time after the Termination Date:

		
	(a)
	use any Confidential Information; or

		
	(b)
	make or use any Copies; or

		
	(c)
	disclose any Confidential Information to any person, company or other organisation whatsoever.

		
	12.2
	The restrictions in clause 12.1 do not apply to any Confidential Information which is in or comes into the public domain other than through the Employee's unauthorised disclosure. 

		
	12.3
	The Employee and the Company confirm that they have kept and agree to keep the existence and terms of this agreement and the circumstances concerning the termination of the Employee's employment confidential, save where such disclosure is to HM Revenue & Customs, required by law, authorised in writing by the other party to this agreement or (where necessary or appropriate) to:

		
	(a)
	(by the Employee) the Employee's immediate family or legal or professional advisers or recruitment consultants engaged by him, provided that they agree to keep the information confidential; or

		
	(b)
	(by the Employee) the Employee's insurer for the purposes of processing a claim for loss of employment; or

		
	(c)
	(by the Company or its Affiliates) to the officers, employees or legal or professional advisers of the Company and/or its Affiliates, provided that they agree to keep the information confidential.

		
	12.4
	The Employee shall not make any adverse or derogatory comment about the Affiliates or the Company, its or their officers or employees and the Company shall use reasonable endeavours to ensure that its employees and officers shall not make any adverse or derogatory comment about the Employee. The Employee shall not do anything which shall, or may, bring the Affiliates or the Company, its officers or employees into disrepute and the Company shall use reasonable endeavours to ensure that its employees and officers shall not do anything which shall, or may, bring the Employee into disrepute.

		
	12.5
	Nothing in this clause shall prevent the Employee from making a protected disclosure under section 43A of the Employment Rights Act 1996 or from making such disclosure as he is required by law to make and nothing in this clause shall prevent the Company from making such disclosure as it is required by law to make.

		
	12.6
	The Company shall pay £20,000 to the Employee as consideration for his entering into the restrictions in this clause, such sum to be paid within 14 days of the later of the dates set out at clause 3.1. The Company shall deduct income tax and National Insurance contributions from this sum.

		
	12.7
	In the event of his non compliance with this clause the Employee shall: (i) immediately repay to the Company the payment set out in clause 12.6 (which shall be recoverable as a debt); (ii) indemnify the Company in respect of any losses it incurs as a result of his breach including loss of income and legal expenses incurred in considering any action against him; and (iii) in the event of the Company choosing to seek to pursue legal action against the Employee (whether by action for injunction, damages or otherwise) indemnify the Company in respect of any losses it incurs from that attempted or successful enforcement including any legal fees or other professional fees.  

		
	13.
	ENTIRE AGREEMENT

		
	13.1
	Each party on behalf of itself agrees with the other party that:

		
	(a)
	this agreement constitutes the entire agreement between the parties and supersedes and extinguishes all previous agreements, promises, assurances, warranties, representations and understandings between them, whether written or oral, relating to its subject matter;

		
	(b)
	in entering into this agreement it does not rely on, and shall have no remedies in respect of, any statement, representation, assurance or warranty (whether made innocently or negligently) that is not set out in this agreement; and

		
	(c)
	it shall have no claim for innocent or negligent misrepresentation or negligent misstatement based on any statement in this agreement.

		
	13.2
	Nothing in this clause shall limit or exclude any liability for fraud.

		
	14.
	VARIATION

No variation of this agreement shall be effective unless it is in writing and signed by the parties (or their authorised representatives).
		
	15.
	THIRD PARTY RIGHTS

		
	15.1
	Except as expressly provided elsewhere in this agreement, no person other than the Affiliates, the Employee and the Company shall have any rights under the Contracts (Rights of Third Parties) Act 1999 to enforce any term of this agreement.

		
	15.2
	The rights of the parties to terminate, rescind or agree any variation, waiver or settlement under this agreement are not subject to the consent of any other person.

		
	16.
	GOVERNING LAW

This agreement and any dispute or claim arising out of or in connection with it or its subject matter or formation (including non-contractual disputes or claims) shall be governed by and construed in accordance with the law of England and Wales.
		
	17.
	JURISDICTION

Each party irrevocably agrees that the courts of England and Wales shall have exclusive jurisdiction to settle any dispute or claim arising out of or in connection with this agreement or its subject matter or formation (including non-contractual disputes or claims).
		
	18.
	SUBJECT TO CONTRACT AND WITHOUT PREJUDICE

This agreement shall be deemed to be without prejudice and subject to contract until such time as it is signed by both parties and dated, when it shall be treated as an open document evidencing a binding agreement.
		
	19.
	COUNTERPARTS

This agreement may be executed in any number of counterparts, each of which, when executed and delivered, shall constitute a duplicate original, but all the counterparts shall together constitute the one agreement.

This agreement has been entered into on the date stated at the beginning of it.

Schedule 1 Reference
To whom it may concern

Dear Sirs

Ralf Mock

Ralf Mock was employed by NACCO Materials Handling Group from 1st February 2006 until 15th April 2015 as Managing Director for Europe, Middle East and Africa. His span of control included all functions within EMEA including:
 
		
	•
	Sales and Marketing

		
	•
	Aftermarket

		
	•
	Manufacturing

		
	•
	Finance

		
	•
	Human Resources

Together this represented responsibility for approximately 1500 employees.
 
Ralf was also responsible for managing relations with an extensive independent dealer network.
 
During his 9 years of service, Ralf performed his duties appropriately in directing a large and complex operating theatre.
 
We thank Ralf for his many contributions in managing the NMHG business in EMEA.

Yours

Schedule 2 Claims
		
	(a)
	for breach of contract or wrongful dismissal;

		
	(b)
	for unfair dismissal, under section 111 of the Employment Rights Act 1996;

		
	(c)
	in relation to the right to a written statement of reasons for dismissal, under section 93 of the Employment Rights Act 1996;

		
	(d)
	 in relation to an unlawful deduction from wages under section 23 of the Employment Rights Act 1996;

		
	(e)
	 in relation to written employment particulars and itemised pay statements, under section 11 of the Employment Rights Act 1996;

		
	(f)
	in relation to working time or holiday pay, under regulation 30 of the Working Time Regulations 1998;

		
	(g)
	 for failure to comply with obligations under the Data Protection Act 1998;

		
	(h)
	arising as a consequence of the United Kingdom's membership of the European Union.

Schedule 3 Adviser's certificate
[ON HEADED NOTEPAPER OF ADVISER]

Private & Confidential:
For the attention of John Short
C/O Andrew Brown
Anderson Strathern LLP
1 Rutland Court
Edinburgh
EH3 8EY

[DATE]

Dear Sirs,

I am writing in connection with the settlement agreement between my client, Ralf Mock, and NACCO Materials Handling Ltd (Company) of today's date (Agreement) to confirm that:

1.    I, Frank Ryan of Barker Gillette LLP, 11 – 12 Wigmore Place, London, W1U 2LU am a Solicitor of the Senior Courts of England and Wales who holds a current practising certificate.

2.    I have given Ralf Mock legal advice on the terms and effect of the Agreement and, in particular, its effect on his ability to pursue the claims specified in Schedule 2 of the Agreement.

3.    I gave the advice to Ralf Mock as a relevant independent adviser within the meaning of the relevant UK acts and regulations including those referred to at clause 6.4.

4.    There is now in force (and was in force at the time I gave the advice referred to above) a policy of insurance or an indemnity provided for members of a profession or professional body covering the risk of claim by Ralf Mock in respect of loss arising in consequence of the advice I have given him.

Yours faithfully,

Frank Ryan
Employee's Adviser

Schedule 4 – Resignation from Offices
Part 1

[DATE]

Dear Sirs,

NACCO Materials Handling Ltd (Company)

I hereby resign from my office as a Director of the Company and from the following positions with immediate effect.

(a)    Supervisory Board Member, NACCO Materials Handling B.V. 
(b)    Director, Yale Materials Handling UK Limited.
(c)    Director, NACCO Materials Handling SpA (Italy).

I hereby acknowledge and confirm that I have no claim or right of action of any kind for compensation or otherwise against the Company or any of the organisations listed above or any of its or their officers or employees in respect of the termination of my office or otherwise. To the extent that any such claim or right of action exists or may exist, I irrevocably waive such claim or right of action and release and forever discharge the Company, each of the organisations listed above, its and their officers and employees from all and any liability in respect thereof.

This letter and any disputes or claims arising out of or in connection with it or its subject matter or formation (including non-contractual disputes or claims) shall be governed by and construed in accordance with the law of England and Wales. The courts of England and Wales shall have exclusive jurisdiction to settle any dispute or claim arising out of or in connection with this letter or its subject matter or formation (including non-contractual disputes or claims).

This document has been executed as a deed and is delivered and takes effect on the date stated at the beginning of it.

Yours faithfully,
	
			
	/s/ Ralf Mock
	 
	 

	Signed as a deed by RALPH MOCK
	 
	[SIGNATURE OF DIRECTOR]

	 
	 
	 

	in the presence of:
	 
	 

	/s/ Claudia Mock
	 
	 

	SIGNATURE OF WITNESS
	 
	 

	NAME OF WITNESS:
	 
	 

	Claudia Mock
	 
	 

	
			
	ADDRESS OF WITNESS:
	 
	 

	 
	 
	 

	 
	 
	 

	OCCUPATION OF WITNESS:
	 
	 

	 
	 
	 

	 
	 
	 

	On [date] at
	 
	[location]

	22 July 2015
	 
	Koenigstein

Schedule 4 – Resignation from Offices
Part 2

NACCO Materials Handling S.p.A.
Via Confalonieri, 2
20060 - Masate (MI)

To the kind attention of the members of the Board of Directors 
To the kind attention of the Chairman of the Board of Statutory Auditors

Re:    Resignation from the office as Member of the Board of Directors of NACCO Materials Handling S.p.A.

Dear Sirs,

The undersigned Ralf Albert Mock, born in Nuernberg (Germany), on November 29, 1955, Italian Fiscal Code MCKRFL55S29Z112R and domiciled for the purpose of my office at the corporate seat of the company, in Via Confalonieri, 2, 20060 Masate (MI), hereby resigns from the office as member of the Board of Directors of NACCO Materials Handling S.p.A., with registered office in Via Confalonieri 2, 20060 - Masate (MI), fiscal code and VAT number 01020710362 (the “Company”), effective immediately. 

To the extent necessary, I hereby declare that I have no claims whatsoever vis-à-vis the Company for any reason or title whatsoever.

Yours faithfully,

	
			
	/s/ Ralf Mock
	 
	 

	RALPH MOCK
	 
	 

	 
	 
	 

	Date: 22 July 2015
	 
	 

Schedule 4 – Resignation from Offices
Part 3

Yale Materials Handling UK Limited
Centennial House
Building 4.5
Frimley Business Park
Frimley
Surrey GU16 7SG

Resignation from the office of Director of Yale Materials Handling UK Limited

Dear Sirs,
The undersigned Ralf Albert Mock, born in Nuernberg (Germany), on November 29, 1955, hereby resigns from the office of director of Yale Materials Handling UK Limited (registered number 01228726) with registered office at Centennial House, Building 4.5, Frimley Business Park, Frimley, Surrey GU16 7SG (the “Company”), effective immediately. 
To the extent necessary, I hereby declare that I have no claims whatsoever vis-à-vis the Company for any reason or title whatsoever.

Yours faithfully,

	
			
	/s/ Ralf Mock
	 
	 

	RALPH MOCK
	 
	 

	 
	 
	 

	Date: 22 July 2015
	 
	 

Schedule 4 – Resignation from Offices
Part 4

The Board of Managing directors of
NACCO Materials Handling B.V.
Nijverheidsweg 29
Nijmegen
The Netherlands

Resignation from the office as Supervisory Director of NACCO Materials Handling B.V.

Dear Sirs,
I, Ralf Albert Mock, born in Nuernberg (Germany), on November 29, 1955, hereby resign my office as Supervisory Director of NACCO Materials Handling B.V., with registered office in Nijverheidsweg 29, Nijmegen, The Netherlands (the “Company”), effective immediately. 
I hereby acknowledge that I have no claim of any nature or kind whatsoever against the Company including, without limiting the generality of the foregoing, any claim for supervisory director’s salary or fees and I hereby forever release the Company from any liability whatsoever in respect thereof.

Yours faithfully,

	
			
	/s/ Ralf Mock
	 
	 

	RALPH MOCK
	 
	 

	Date: 22 July 2015
	 
	 

	 
	 
	 

	Executed as a deed by NACCO Materials 
	 
	 

	Handling Ltd acting by , a director,
	 
	 

	 
	 
	[DIRECTOR]

	in the presence of:
	 
	 

	/s/ Claudia Mock
	 
	 

	SIGNATURE OF WITNESS
	 
	 

	NAME OF WITNESS:
	 
	Claudia Mock

	ADDRESS OF WITNESS:
	 
	 

	 
	 
	 

	 
	 
	 

	OCCUPATION OF WITNESS:
	 
	Spouse

	
			
	On 22 July 2015
	 
	Koenigstein

	 
	 
	 

	Signed as a deed by Ralf Mock
	 
	 

	/s/ Ralf Mock
	 
	 

	 
	 
	 

	in the presence of:
	 
	 

	/s/ Claudia Mock
	 
	 

	SIGNATURE OF WITNESS
	 
	 

	NAME OF WITNESS:
	 
	Claudia Mock

	ADDRESS OF WITNESS:
	 
	 

	 
	 
	 

	 
	 
	 

	OCCUPATION OF WITNESS:
	 
	Spouse

	 
	 
	 

	On [date] at
	 
	[location]

	22 July 2015
	 
	KoenigsteinExhibit 10.1.1

 

SECOND AMENDMENT TO LEASE

 

THIS SECOND AMENDMENT TO LEASE (hereinafter referred to as the “Amendment”) is made as of the 21st day of January, 2016, between SENECA MEADOWS CORPORATE CENTER III L.L.L.P., a Maryland limited liability limited partnership, successor-in-interest by name change of SENECA MEADOWS CORPORATE CENTER III LIMITED PARTNERSHIP, a Maryland limited partnership (hereinafter referred to as “Landlord”); and SENSEONICS, INCORPORATED, successor by change of name of SENSORS FOR MEDICINE AND SCIENCE, INC., a Delaware corporation, qualified to transact business and in good standing under the laws of the State of Maryland (hereinafter referred to as “Tenant”).

 

RECITALS:

 

WHEREAS, Landlord and Tenant entered into that certain lease agreement dated February 4, 2008 (the “Original Lease”), as modified by that certain Certificate of Delivery of Possession and Commencement Date of Lease dated March 20, 2008 (the “First Certificate”), that certain First Amendment to Lease dated July 26, 2012 (the “First Amendment”), and that certain Certificate of Delivery of Possession of Expansion Space dated September 25, 2012 (the “Second Certificate”) (the Original Lease, the First Certificate, the First Amendment and the Second Certificate shall hereinafter collectively be referred to as the “Lease”), for that certain portion of commercial office and lab space in the building known as Building #7 at Seneca Meadows Corporate Center (the “Building”), situated on that certain parcel of land known as “Lot 5, Block B” in the subdivision known as “SENECA MEADOWS CORPORATE CENTER” and recorded in Plat Book 194 at Plat No. 21147 among the Land Records of Montgomery County, Maryland (the “Land”), said premises being known and described as 20447, 20449 and 20451 Seneca Meadows Parkway, Germantown, Maryland 20876, and deemed to consist of 20,916 square feet (hereinafter referred to as the “Original Premises”), as more particularly described in the Lease and as shown and outlined on the drawing of the Building attached hereto as  Exhibit “A” and made a part hereof; and

 

WHEREAS, the current Term of the Lease will expire May 31, 2018 (the “Current Term”); and

 

WHEREAS, pursuant to Section 6.1 of the First Amendment, which modified and amended Section 29 of the Original Lease, Tenant had the right and option (the “Renewal Option”) to renew and extend the Current Term of the Lease for one (1) additional consecutive period of five (5) years (the “Renewal Term”), to commence June 1, 2018 and expire May 31, 2023; and

 

WHEREAS, Tenant desires to (i) exercise its Renewal Option to renew and extend the Current Term of the Lease for the Renewal Term set forth above, and (ii) lease certain additional space in the Building, known as 20443 — 20445 Seneca Meadows Parkway, Germantown, Maryland 20876, deemed to consist of 11,889 rentable square feet (the “Additional Expansion Space”), which Additional Expansion Space is adjacent to the Original Premises, as more

 

 

particularly shown and outlined on the drawing of the Building attached hereto as Exhibit “B” and made a part hereof; and

 

WHEREAS, Landlord and Tenant by this Amendment mutually desire to modify and amend the terms and provisions of the Lease as more fully set forth herein below; and

 

WHEREAS, the foregoing Recitals are incorporated herein and made a part of this Amendment.

 

NOW, THEREFORE, in consideration of the foregoing and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties intending to be legally bound do hereby covenant and agree as follows:

 

1.                                      TERM.  Tenant hereby exercises the Renewal Option for the Renewal Term, effective upon execution of this Amendment, and the Current Term of the Lease is hereby extended for an additional consecutive period of five (5) years, commencing June 1, 2018 and expiring May 31, 2023 (the “Extended Term”).  The Extended Term shall be upon all of the same terms and conditions of the Lease except as otherwise modified and amended herein and except for Section 6.2 of the First Amendment, which is hereby deleted in its entirety.

 

2.                                      DEMISED PREMISES.  Commencing on the date that Landlord delivers to Tenant possession of the Additional Expansion Space (the “Additional Expansion Space Delivery Date”), with Landlord’s Work therein Substantially Complete (as set forth in Section 5 below), and continuing thereafter during the remainder of the Current Term and the Extended Term (hereinafter collectively referred to as the “Term”) of the Lease, Section 1(A) of the Lease is hereby modified and amended to provide that the Demised Premises shall include the Additional Expansion Space in addition to the Original Premises.  Landlord does hereby lease unto Tenant, and Tenant does hereby take and rent from Landlord, commencing as of the Additional Expansion Space Delivery Date, the Additional Expansion Space pursuant to the Lease as hereby amended.  Landlord shall provide Tenant with at least fifteen (15) days written notice prior to the Additional Expansion Space Delivery Date.  As of the Additional Expansion Space Delivery Date, the Original Premises together with the Additional Expansion Space shall for all purposes and provisions of the Lease collectively be referred to as the “Demised Premises” or the “Premises” and shall be deemed to contain 32,805 rentable square feet, all as more particularly shown and outlined on the drawing of said Demised Premises attached hereto as Exhibit “B” and made a part hereof.

 

2.1                      Tenant agrees to execute and return to Landlord within fifteen (15) days of receipt a statement furnished by Landlord acknowledging Tenant’s acceptance of Landlord’s delivery of possession of the Additional Expansion Space and setting forth the actual Additional Expansion Space Delivery Date and commencement of all of Tenant’s covenants and obligations under the Lease as to the Additional Expansion Space, and changes, if any, in the rental schedule set forth in Section 3 below.  Said statement shall be similar in form to the Certificate attached hereto as Exhibit “D” and made a part of this Amendment.

 

3.                                      RENTAL.  Commencing as of the Additional Expansion Space Delivery Date and continuing thereafter during each Lease Year of the Term of the Lease as set forth above, Tenant

 

2

 

agrees to pay to Landlord, as Basic Annual Rental for the Demised Premises (including the Additional Expansion Space), the amount specified for each respective Lease Year in the following table (which shall replace the table set forth in Section 3 of the First Amendment), said amount to be due and payable in equal monthly installments of Basic Monthly Rental during such Lease Year in advance and without deduction, set off or demand, at the times and in the manner indicated in the Lease:

 

	
Lease Year
    	
 
    	
Basic Monthly Rental
    	
 
    	
Basic Annual Rental
    	
 
    	
Rental Rate/SF*
    	
 
    
	
 
    	
 
    	
 
    	
 
    	
 
    	
 
    	
 
    	
 
    
	
5/1/16 - 5/31/16**
    	
 
    	
$
    	
48,715.00
    	
 
    	
$
    	
48,715.00
    	
 
    	
$
    	
17.82
    	
 
    
	
6/1/16 - 5/31/17
    	
 
    	
$
    	
49,809.00
    	
 
    	
$
    	
597,708.00
    	
 
    	
$
    	
18.22
    	
 
    
	
6/1/17 - 5/31/18
    	
 
    	
$
    	
51,312.00
    	
 
    	
$
    	
615,744.00
    	
 
    	
$
    	
18.77
    	
 
    
	
6/1/18 - 5/31/19
    	
 
    	
$
    	
50,055.00
    	
 
    	
$
    	
600,660.00
    	
 
    	
$
    	
18.31
    	
 
    
	
6/1/19 - 5/31/20
    	
 
    	
$
    	
51,559.00
    	
 
    	
$
    	
618,708.00
    	
 
    	
$
    	
18.86
    	
 
    
	
6/1/20 - 5/31/21
    	
 
    	
$
    	
53,089.00
    	
 
    	
$
    	
637,068.00
    	
 
    	
$
    	
19.42
    	
 
    
	
6/1/21 - 5/31/22
    	
 
    	
$
    	
54,702.00
    	
 
    	
$
    	
656,424.00
    	
 
    	
$
    	
20.01
    	
 
    
	
6/1/22 - 5/31/23
    	
 
    	
$
    	
56,343.00
    	
 
    	
$
    	
676,116.00
    	
 
    	
$
    	
20.61
    	
 
    

 

*  all base annual rental rates are “NNN”

**  assumes an Additional Expansion Space Delivery Date of May 1, 2016, with one (1) calendar month remaining in the then operative Lease Year; subject, however, to adjustment should the actual Additional Expansion Space Delivery Date be on a date prior to or after May 1, 2016

 

3.1                               In addition to the Basic Annual Rental as set forth above, Tenant shall pay to Landlord, as Additional Rent, at the times and in the manner indicated in the Lease, Tenant’s Pro-Rata Share of Landlord’s Expense Estimate for Operating Expenses, as specified in Section 4 and Section 8 of the Lease, for each calendar year in accordance with Section 4(E) of the Lease, and such other sums as are required to be paid by Tenant for the Demised Premises pursuant to the terms of the Lease as amended herein.

 

3.2                               Notwithstanding anything hereinabove to the contrary, should the Additional Expansion Space Delivery Date be a date other than the first day of the calendar month, then the monthly installment of Basic Annual Rental and Tenant’s Monthly Share of estimated Operating Expenses to be paid by Tenant to Landlord for any such partial month of use and occupancy of the Additional Expansion Space shall be pro-rated on a per diem basis from the Additional Expansion Space Delivery Date to the end of the month.(1)  In addition to the pro-rated per diem monthly Rent for the Additional Expansion Space, Tenant would pay the full monthly installment of Rent for the Original Premises.

 

3.3                               Until the Additional Expansion Space Delivery Date, Tenant shall continue to pay Basic Monthly Rental for the Original Premises (prior to addition of the Additional Expansion Space pursuant to this Amendment) in accordance with the rental table set

 

(1) For example, if the Additional Expansion Space Delivery Date should be May 15, 2016, then Basic Monthly Rental payable for such partial month of use and occupancy of the Additional Expansion Space in May shall be pro-rated on a per diem basis for 17 days, from 5/15 — 5/31/16, at the per diem rate determined, as follows: 11,889 SF x $17.82 SF ÷ 12 mos. ÷ 31 days = $569.52 day x 17 days = $9,681.84 as the per diem Basic Monthly Rental payable for the Additional Expansion Space, plus Tenant’s Monthly Share of estimated Operating Expenses pro-rated on a per diem basis for the Additional Expansion Space in the same manner.

 

3

 

forth in Section 3 of the First Amendment, as applicable to the current operative Lease Year expiring May 31, 2016, and Tenant’s Monthly Share of Operating Expenses for the Original Premises.

 

4.                                      TENANT’S PRO-RATA SHARE.  Section 4(B) of the Lease is hereby modified to provide that, effective as of the Additional Expansion Space Delivery Date and continuing thereafter during the Extended Term of the Lease, Tenant’s Pro Rata Share under the Lease shall be increased to Sixty-One and 83/100 percent (61.83%), which percentage is agreed to represent the ratio that the gross rentable floor area of the Demised Premises (inclusive of the Expansion Space Space) (32,805 square feet) bears to the total approximate gross rentable floor area of the Building (53,054 square feet) of which the Demised Premises forms a part.

 

5.                                      TENDER OF POSSESSION; LANDLORD’S WORK.  The Tenant agrees to accept possession of the Additional Expansion Space, when delivered by Landlord as established in the notice to be given by Landlord to Tenant pursuant to Section 2 above, upon the agreements and covenants set forth in the Lease, as amended by this Amendment.  The Additional Expansion Space shall be delivered by Landlord to Tenant and shall be accepted by Tenant with Landlord’s Work therein Substantially Complete.  Landlord’s Work shall consist of the leasehold improvements to be furnished and installed by Landlord, at Landlord’s sole cost and expense, in the Additional Expansion Space, as shown on the drawing prepared by Banta Campbell Architects, Inc. (the “TI Architect”) identified as SK-3.2 and dated December 14, 2015 (the “Space Plan”), which Space Plan has been mutually agreed to by the parties and is attached hereto as Attachment 1 to Exhibit “C” and made a part hereof, and as detailed in the plans and specifications to be prepared by the TI Architect and other such design consultants selected by Landlord, and in the “Design Intent Guidelines” as described in Attachment 2 to Exhibit “C”.  Minkoff Development Corporation (“MDC”), an affiliate of Landlord and a licensed and insured contractor in the State of Maryland, shall act as general contractor and construction manager for Landlord’s Work.  Upon expiration or earlier termination of the Lease, Tenant shall have no obligation to remove any of Landlord’s Work, except as otherwise specified by Landlord in writing or as part of the Approved Working Drawings referenced in Exhibit “C”.

 

6.                                      RENEWAL OPTION AND RENEWAL TERM; RENEWAL RENTAL.

 

6.1                   RENEWAL OPTION AND RENEWAL TERM.  Provided that no Event of Default or Event of Bankruptcy of Tenant exists under the Lease, as modified by this Amendment, and no event or condition exists which with the giving of notice or the passage of time, or both, would become an Event of Default, either at the time of exercise of this renewal option, or at the time of commencement of the renewal term provided herein, Tenant shall have the right and option (the “Renewal Option”) to renew and extend the Term of the Lease, as modified by this Amendment, “as is” for one (1) additional consecutive period of five (5) years (the “Renewal Term”), commencing June 1, 2023 and expiring May 31, 2028.  The Renewal Option herein may be exercised only by written notice given by Tenant to Landlord at least twelve (12) months prior to expiration of the Extended Term under this Amendment herein (the “Renewal Notice”).  Such Renewal Term shall be upon all of the same terms and conditions of the Lease, as hereby amended, except that Landlord shall not be obligated to pay for or grant Tenant any allowance for any work or perform any Alterations or leasehold improvements in the

 

4

 

Demised Premises during or with respect to the Renewal Term.  If Tenant should fail to timely exercise its Renewal Option for the Renewal Term provided herein, then the Renewal Option right shall automatically lapse and become null and void.  The Renewal Option herein shall apply only with respect to the entire Demised Premises under the Lease, and shall not be assignable by Tenant (other than to a Tenant Affiliate as defined in the Lease) without Landlord’s prior written consent in each instance.

 

6.2                               RENEWAL RENTAL.  During each respective Lease Year of the Renewal Term, the Tenant agrees to pay to Landlord as Basic Annual Rental for the Demised Premises, the amount specified for that Lease Year in the following table, said amount to be due and payable in equal monthly installments of Basic Monthly Rental during such Lease Year in advance and without deduction, set off or demand, except as may otherwise be provided herein, on the first (1st) day of each calendar month in such Lease Year, namely:

 

	
Lease Year
    	
 
    	
Basic Monthly Rental
    	
 
    	
Basic Annual Rental
    	
 
    
	
 
    	
 
    	
 
    	
 
    	
 
    	
 
    
	
1
    	
 
    	
$
    	
58,033.00
    	
 
    	
$
    	
696,396.00
    	
 
    
	
2
    	
 
    	
$
    	
59,774.00
    	
 
    	
$
    	
717,288.00
    	
 
    
	
3
    	
 
    	
$
    	
61,567.00
    	
 
    	
$
    	
738,804.00
    	
 
    
	
4
    	
 
    	
$
    	
63,414.00
    	
 
    	
$
    	
760,968.00
    	
 
    
	
5
    	
 
    	
$
    	
65,317.00
    	
 
    	
$
    	
783,804.00
    	
 
    

 

In addition to the Basic Monthly Rental, Tenant shall pay to Landlord, at the time and in the manner indicated in the Lease, the Operating Expenses, other items of Additional Rent, and all other sums required to be paid by Tenant pursuant to the terms of the Lease, as modified by this Amendment.

 

7.                                      RIGHT OF FIRST OFFER.  Section 35 of the Lease (captioned “Option to Lease Additional Space”) shall continue in full force and effect during the remainder of the Term of the Lease.

 

8.                                      BROKERAGE.  Landlord and Tenant each represent, acknowledge, and warrant to the other that this Amendment and all transactions leading up the execution of this Amendment were negotiated and consummated directly and solely between Landlord and Tenant and that, neither party has been represented by any real estate broker or agent in connection with this Lease.  Each party agrees to indemnify, defend and hold harmless the other from and against any and all damages, costs or expense, including but not limited to, court costs, litigation expenses and reasonable attorneys’ fees, arising out of any claim or action by any broker or other person for any commission, fee or other compensation in connection with this transaction based upon or arising out of any action by Landlord or Tenant or anyone acting on their behalf, respectively.

 

9.                                      MORTGAGEE CONSENT.  Tenant understands and acknowledges that the effectiveness of this Amendment is expressly contingent on Landlord obtaining the written consent of Landlord’s permanent mortgage lender (the “Lender”) for this Amendment. Landlord hereby represents that it will exercise all commercially reasonable efforts to obtain such Lender consent within thirty (30) days after execution of this Amendment.  If requested

 

5

 

by Lender upon review of this Amendment, Tenant agrees to join with Landlord in executing such additional documents as such Lender reasonably may require for its consent to this Amendment, provided the same does not increase the rent or other amounts payable by Tenant hereunder, nor alter Tenant’s rights and/or obligations or Landlord’s rights and/or obligations under the Lease or this Amendment.

 

10.                               MISCELLANEOUS PROVISIONS.

 

10.1                        This Amendment, including the exhibits referenced herein and attached hereto, shall constitute the full and entire agreement between Landlord and Tenant with respect to the subject matter herein.  Any prior correspondence, memoranda, understandings, offers, negotiations and agreements, oral or written, are replaced by this Amendment.  This Amendment may not be modified or amended except in writing, signed by the parties hereto.

 

10.2                        This Amendment shall not be binding upon Landlord until delivery by Landlord of a fully executed original of same to Tenant.  The provisions hereof shall bind and inure to the benefit of Tenant and Landlord and their respective successors and assigns, and shall be construed under the laws of the State of Maryland.  Further, the parties executing this document on behalf of Tenant and Landlord hereby represent and warrant to Landlord or Tenant as the case may be that each of the individuals signing this Amendment on behalf of Landlord and Tenant has the full right and requisite power, capacity and authority to execute and deliver this Amendment as a binding and valid obligation on behalf of Tenant or Landlord as the case may be.

 

10.3                        Time shall be of the essence regarding all obligations and duties of Tenant and Landlord under this Amendment.

 

10.4                        Tenant confirms that Landlord is not in default under any provision of the Lease, and that Landlord has fully performed all of its obligations under the Lease through the date hereof.

 

10.5                        The section headings or captions appearing in this document are inserted only as a matter of convenience and do not define, limit, construe, or describe the scope or intent of the sections of this Amendment, nor in any way affect this instrument.

 

10.6                        All defined terms used herein shall have the meanings given them in the Lease, unless otherwise defined herein.

 

10.7                        The Landlord and Tenant hereby waive all rights to trial by jury in any litigation involving this Amendment.  If Tenant is in an Event of Default under any provision of this Amendment, it is agreed that Landlord shall have all of the rights and remedies available at law and/or in equity as provided in the Lease.

 

10.8                        Submission of this Amendment for examination or signature by Tenant and any negotiations in connection therewith shall not be effective as an amendment to the Lease or otherwise until execution and delivery hereof by Landlord and Tenant.

 

6

 

10.9                        The parties confirm that they have been represented by their own counsel or have had the opportunity to secure independent advice from counsel of their own choosing and each acknowledges and agrees that they have had the opportunity to fully negotiate the terms hereof and modify the draftsmanship of this Amendment.  Therefore, the terms of this Amendment shall be construed and interpreted without any presumption, inference, or rule requiring construction or interpretation of any provision of this Amendment against the interest of the party causing this Amendment or any portion thereof to be drafted.

 

10.10                 Except as expressly modified by this Amendment herein, the Lease between the parties, as previously modified and amended, shall be and remain in full force and effect.  The provisions of this Amendment shall prevail and control over anything to the contrary hereof contained in the Lease.

 

10.11                 Each party acknowledges and agrees to fully cooperate with the other party and to join in with the other party to execute and deliver such other and further documents or instruments as may be reasonable or necessary to effectuate the terms and provisions of this Amendment.

 

10.12                 This Amendment may be executed in two or more counterparts each of which shall be deemed an original, and all of which when taken together shall constitute one and the same instrument.  The parties further agree that facsimile signatures or signatures scanned into PDF (or similar) format and sent by e-mail shall be deemed original signatures.

 

[BALANCE OF PAGE INTENTIONALLY LEFT BLANK;

SIGNATURES ON FOLLOWING PAGE]

 

7

 

IN WITNESS WHEREOF, the Landlord has caused this Amendment to be executed in its name by its duly authorized general partner, and the Tenant has caused this Amendment to be signed, witnessed or attested on its behalf in its corporate name by its duly authorized officers, all done as of the date first above written.

 

	
 
    	
LANDLORD:
    
	
 
    	
 
    
	
 
    	
SENECA MEADOWS CORPORATE CENTER   III L.L.L.P., a Maryland limited liability limited   partnership
    
	
 
    	
 
    
	
WITNESS:
    	
By:
    	
PNC Realty, Inc.,   a Maryland corporation
   its General Partner
    
	
 
    	
 
    
	
 
    	
 
    
	
/s/ [Illegible]
    	
By:
    	
Paul N. Chod
    
	
 
    	
 
    	
Paul N. Chod, President
    
	
 
    	
 
    
	
 
    	
 
    
	
 
    	
TENANT:
    
	
 
    	
 
    
	
WITNESS/ATTEST:
    	
SENSEONICS, INCORPORATED
    
	
 
    	
 
    
	
 
    	
a Delaware corporation
    
	
 
    	
 
    
	
 
    	
 
    
	
/s/ Rick Sullivan
    	
By:
    	
R. Don Elsey (SEAL)
    
	
 
    	
 
    
	
Rick Sullivan,   Corporate Controller
    	
 
    	
R. Don Elsey, CFO
    
	
(Print   Name & Title)
    	
 
    	
(Print   Name & Title)
    

 

8

 

EXHIBIT “A”

 

Drawing of Building #7, Seneca Meadows Corporate Center

locating the Original Premises at

20447, 20449 and 20451 Seneca Meadows Parkway, Germantown, MD 20876

 

 

9

 

EXHIBIT “B”

 

Demised Premises

(Original Premises and Additional Expansion Space)

located at

20443, 20445, 20447, 20449 and 20451 Seneca Meadows Parkway, Germantown, MD 20876

 

 

10

 

EXHIBIT “C”

 

LANDLORD’S WORK

(Additional Expansion Space)

 

C-1.                         SPACE PLAN.

 

Landlord shall construct or cause to be constructed all of the leasehold improvements for the Additional Expansion Space comprising the Landlord’s Work (defined below), as shown on the Space Plan drawing prepared by the TI Architect, approved by Landlord and Tenant, and referenced as SK-3.2, dated  December 14, 2015, a copy of which Space Plan is attached as Attachment 1 to Exhibit “C” hereto.  Attached as Attachment 2 to Exhibit “C” are the Design Intent Guidelines applicable to the Landlord’s Work (the “Design Intent Guidelines”).

 

C-2.                         WORKING DRAWINGS.

 

The TI Architect shall, within thirty (30) days after execution of this Amendment, prepare a complete set of architectural, mechanical, electrical, plumbing and all other working drawings, as may be necessary, to show the Landlord’s Work (the “Working Drawings”).  The Working Drawings shall be of sufficient detail for Landlord (i) to obtain contractors’ bids from all trades for and to perform the work described on the Space Plan; (ii) to secure building permits from the requisite governmental authorities having jurisdiction over same; and (iii) to determine and indicate on the Working Drawings the portion of Landlord’s Work, if any, which Tenant is to remove by expiration or termination of the Lease.  The Working Drawings shall conform to, be consistent with, and cover only the work and materials described and contemplated in the Space Plan.  Within five (5) business days after receipt of the Working Drawings, as modified by any such revisions requested by Landlord, the Landlord and Tenant will initial same to confirm their mutual approval thereof (the “Approved Working Drawings”).  Tenant’s approval of the Working Drawings shall automatically be deemed given if not refused by Tenant in writing with full and proper reasons stated therefore within the time period aforesaid.  All costs of preparing, revising, copying and delivering the Space Plan, Working Drawings and revisions thereof, and Approved Working Drawings shall be paid by Landlord.  Tenant will fully cooperate with Landlord, MDC and Landlord’s subcontractors, and meet with them to review any site conditions or issues concerning Landlord’s Work when requested.

 

C-3.                         LANDLORD’S WORK.

 

The work to be performed as shown on the Approved Working Drawings is herein called “Landlord’s Work”, and shall be performed by MDC, as Landlord’s general contractor and construction manager, and/or its agents, employees or subcontractors using existing materials or new materials of good quality (as respectively identified in the Design Intent Guidelines and the Approved Working Drawings) and structurally sound and free from any defects or deficiencies and in accordance with all applicable codes, ordinances and Laws (as that term is defined in the Lease), and in a good and workmanlike manner.  Landlord will indicate on the Approved Working Drawings the portions of Landlord’s Work, if any, which Tenant is to remove by expiration or termination of the Lease; and Tenant will timely comply with such requirements

 

11

 

and repair any damage to the Demised Premises, Building, Common Areas or Land caused thereby at its own expense.  Contractors will be selected by MDC on the basis of several factors, including but not limited to cost, quality of work, ability to staff the job, schedule and reputation.  All materials and finishes used in Landlord’s Work shall be as specified on the Design Intent Guidelines and the Approved Working Drawings, or, if unspecified, shall be Landlord’s Building standard materials and finishes, from which Tenant shall make its selection of floor covering materials and paint colors. MDC reserves the right (i) to make substitutions of materials of equivalent grade and quality when and if any specified material shall not be readily and reasonably available, and (ii) to make changes necessitated by conditions met in the course of construction, provided that Tenant’s approval is first obtained prior to any substantial change from the Approved Working Drawings (which approval shall not be unreasonably withheld, conditioned or delayed so long the proposed changes are in general conformity with the Design Intent Guidelines and the Approved Working Drawings; and which approval shall be deemed given if not refused in writing with full proper reasons stated by Tenant within three (3) business days after Landlord’s written request).  All of Landlord’s Work shall be considered leasehold improvements (except as may otherwise be specified herein) and shall be deemed to be the property of Landlord and shall not be removed from the Demised Premises without the express prior written consent of Landlord.

 

C-4.                         SUBSTANTIAL COMPLETION.

 

Landlord shall exercise its reasonable best efforts to cause Landlord’s Work to be Substantially Complete by May 1, 2016, subject to extensions of said date by (a) “Tenant Delays” and (b) “Force Majeure Delays.”  For purposes hereof, the phrase “Tenant Delays” shall mean all delays in performance of Landlord’s Work directly caused or resulting from any act, omission or Event of Default hereunder by Tenant, its Permittees or contractors, or by any “Change Orders”, or the inclusion of any “Special Items” in Landlord’s Work (as hereinafter defined), provided the same shall cause a delay.  Notwithstanding anything contained herein to the contrary, in the event that Landlord reasonably believes any component or item included in Landlord’s Work, as requested by Tenant, to be subject to the provision for “Special Items” set forth below, Landlord shall notify Tenant in writing (prior to the date of Landlord’s and Tenant’s final approval of the Approved Working Drawings) as to the estimated number of calendar days such item(s) shall delay the completion of the Landlord’s Work.  The phrase “Force Majeure Delays” shall mean, for purposes hereof, any delays in performance of Landlord’s Work caused by: (a) strikes, lockouts or other labor or industrial disturbance; (b) shortage or unavailability of materials, utilities or labor; (c) civil disturbance; (d) orders of any government, court or regulatory body claiming jurisdiction; (e) exercise of police power; (f) act of the public enemy; (g) riot, war, sabotage, blockage or embargo; (h) acts of God; (i) lightning, earthquake, fire, storm, hurricane, tornado, flood, washout, explosion or casualty damage; (j) delay in issuance of any permits, inspections, approvals or use and occupancy certificate, if required, by any governmental authority having jurisdiction over the Demised Premises or Building in which the Demised Premises are a part (provided Landlord has timely applied for and provided everything necessary to obtain required permits and/or certificates and/or has timely requested any required inspections); or (k) any cause whatsoever beyond the reasonable control of Landlord.  The phrase “Change Orders” as used herein shall mean any changes in the Approved Working Drawings requested by Tenant.  When Tenant requests a Change Order or Special Item, MDC

 

12

 

will provide Tenant with an estimate of the cost of the Change Order or Special Item and the anticipated delay, if any, that will result therefrom within three (3) business days of said request, and Tenant shall have an additional three (3) business days thereafter to authorize, modify or revoke said Change Order or Special Item.  Tenant shall pay Landlord, in cash, within thirty (30) days after each written demand therefor, for the cost of any such Change Orders or Special Items.  Landlord’s Work shall be deemed “Substantially Complete” (which phrase shall include phrases of similar import used herein concerning Landlord’s Work) when all of the following have occurred: (i) when so certified in writing by Landlord in its reasonable judgment (or such earlier date when such work could have been Substantially Complete absent any Tenant Delays, as so determined in writing to Tenant by Landlord, in its reasonable judgment; (ii) when such work has been completed (except for minor Punch List Items) to the extent reasonably necessary for Tenant to occupy the Additional Expansion Space for its intended use; and (iii) when the requisite Use and Occupancy Certificate (or permission to occupy pending issuance thereof has been issued by the Department of Permitting Services of Montgomery County, Maryland) has been obtained by Landlord, if required.  Landlord shall also determine and certify to Tenant in writing the existence and period of any Force Majeure Delays, Tenant Delays and any delays caused by Change Orders.  However, if Tenant disputes any such determinations or certifications made by Landlord, then the matter shall first be submitted to non-binding mediation by the TI Architect (the “Mediator”) and, if not resolved, then any such disputes shall be resolved by arbitration pursuant to the Construction Industry rules of the American Arbitration Association, and the decision in such arbitration shall be binding and conclusive on the parties, subject to the parties’ rights, pursuant to the Rules of the American Arbitration Association and/or the law to appeal or otherwise challenge any such decision.  “Special Items” as used herein shall mean all materials and other items forming part of Landlord’s Work which were requested by Tenant over and above Landlord’s Building standard materials and finishes, as set forth in the Design Intent Guidelines attached hereto, or which are not readily available in adequate quantities in the Metropolitan Area of Washington, D. C., or which require more than thirty (30) days to order and obtain (as reasonably determined and certified in writing by Landlord to Tenant, or by the Mediator in mediation, or by arbitration as aforesaid if disputed by Tenant).  In making any such determination of Substantial Completion of Landlord’s Work, Landlord or Mediator or the arbitrator as aforesaid shall not take into account the incomplete status of any Change Orders or Special Items or “Punch List Items”.  The phrase “Punch List Items”, as used herein, shall mean any unperformed or incomplete elements of Landlord’s Work which, individually or in the aggregate, are minor in character and do not materially interfere with Tenant’s access to, use or enjoyment of the Additional Expansion Space or prevent Tenant from legally occupying the Demised Premises; all as reasonably determined by Landlord or in mediation by the Mediator or by arbitration aforesaid if Tenant disagrees with the determination in regard thereto.  Landlord shall use commercially reasonable efforts to cause such Punch List Items to be completed within thirty (30) days after Substantial Completion of Landlord’s Work (or as soon thereafter as is reasonably practicable).  After the date of Substantial Completion and delivery of the Additional Expansion Space to Tenant, Tenant shall provide Landlord, MDC and its contractors access to the Additional Expansion Space on request at all reasonable times during normal business hours and on weekends, as coordinated with Tenant, to perform work on the Punch List Items and Tenant shall not interfere with such work provided Landlord, MDC and its contractors will use reasonable efforts to minimize any disruption to Tenant’s use of the Additional Expansion Space.

 

13

 

C-5.                         TENANT’S WORK.

 

At least fifteen (15) days prior to Substantial Completion of the Landlord’s Work, Tenant at its own risk and expense and at no cost to Landlord, shall have the right to enter the Building and Additional Expansion Space to install Tenant’s Cabling and Tenant’s furniture, decorations, furnishings, trade fixtures and equipment (“Tenant’s FF&E”) in the Additional Expansion Space necessary for conduct of its business as permitted in the Lease.  All such installation of Tenant’s FF&E and all other work performed by Tenant in or for the Additional Expansion Space (“Tenant’s Work”) shall be performed in compliance with all provisions and requirements of this Lease including, but not limited to, Section 3 and Section 6 thereof, and using qualified, licensed contractors reasonably acceptable to Landlord.  Tenant shall not engage any labor to perform Tenant’s Work which conflicts with the type of labor engaged by Landlord to perform Landlord’s Work or any other work in the Building, and Tenant shall cease use of any such conflicting labor immediately on Landlord’s request.  Tenant shall perform Tenant’s Work in such a manner so as not to damage, delay or interfere with Landlord’s Work.  Any damage to Landlord’s Work or to the Additional Expansion Space caused by Tenant and/or its Permittees shall be promptly repaired by and at the sole expense of Tenant.  Any failure of Tenant and/or its Permittees to comply with the terms of this Section shall be deemed a Tenant Delay for purposes of the Lease, as modified by this Amendment.  Tenant shall not commence performance of any work or installation of any of its property in the Additional Expansion Space, nor apply for any permits that would delay Landlord’s Work or acquisition of permits therefor, until notified in writing by Landlord that Tenant may commence such activities.  Landlord will not unreasonably withhold, condition or delay such notification.  Tenant and its Permittees will fully cooperate in (and not interfere with or delay) Landlord’s Work.

 

C-6.                         NOTICE.

 

Landlord will give Tenant at least fifteen (15) days prior written notice of the date Landlord expects to tender to Tenant possession of the Additional Expansion Space with Landlord’s Work Substantially Complete (as required in this Amendment), and will promptly notify Tenant as to any change in such estimated date as soon as the same is known to Landlord. Tenant’s acceptance of possession of the Additional Expansion Space shall include therein Tenant’s acceptance of the Landlord’s Work, subject to Section 3(C) of the Lease, and to the attachment thereto of a complete list of Punch List Items which shall be prepared by Landlord and Tenant and signed by Tenant and Landlord on the date Landlord tenders to Tenant possession of the Additional Expansion Space or as soon thereafter as may be practical.  Notwithstanding the foregoing, acceptance of possession by Tenant of the Additional Expansion Space shall not be a waiver of its rights to have Landlord deliver the completed Landlord’s Work, including any incomplete or defective work which was not known or readily discoverable upon acceptance of possession.  Landlord shall promptly, after receiving written notice thereof by Tenant, correct any and all such defects or omissions at its sole cost and expense.

 

C-7.                         CODE COMPLIANCE AND WARRANTY.

 

Landlord represents and warrants to Tenant that Landlord’s Work to be performed in the Additional Expansion Space will be in compliance with all applicable Laws, as well as

 

14

 

requirements of the county Fire Marshal, or any similar body having jurisdiction over the Additional Expansion Space and the Building of which the Additional Expansion Space are a part.  Landlord will warrant Landlord’s Work to be free of defects in materials and workmanship for a period of one (1) year from the Additional Expansion Space Delivery Date (except for any repairs or replacements by Tenant, at its expense, of any damage to the Additional Expansion Space for which Tenant is responsible as provided in the Lease).

 

15

 

ATTACHMENT 1 TO EXHIBIT “C”

 

Space Plan for Additional Expansion Space

 

 

16

 

ATTACHMENT 2 TO EXHIBIT “C”

 

Design Intent Guidelines

 

These items are to be used in conjunction with the Space Plan attached to Exhibit “C” and incorporated into the Working Drawings to be prepared by the TI Architect, and are meant to define general materials to be used.  Unless otherwise noted the items listed are to be furnished and installed by Landlord as part of Landlord’s Work and other provisions set forth in the Lease.

 

A. PARTITIONS

 

1.              Interior Partitions: Building standard 2-1/2” metal studs with one layer of 1/2” gypsum board on each side. Walls to terminate at the underside of the ceiling grid.  Walls to be finished and painted.

 

This spec to be used in the following areas:

 

·                  All walls between offices.

·                  All areas not specifically listed below.

 

2.              Full Height Interior Partitions: Building standard 2-1/2” metal studs with one layer of 1/2” gypsum board on each side. Walls to terminate at the underside of the deck.  Walls to be finished and painted.

 

This spec to be used in the following areas:

 

·                  Storage rooms if required by code.

 

3.              Sound Insulated Partitions — Variation A: Building standard 3-5/8” metal studs with one layer of 1/2” gypsum board on each side. Walls to terminate 4” above finished ceiling.  Wall to be insulated with 3-1/2” thermafiber insulation.  Walls to be finished and painted.

 

This spec to be used in the following areas:

 

·                  Walls between the large open areas and the perimeter offices.

·                  Bathroom Core.

 

4.              Glass sidelight:  Drywall return with stainless steel channel on the top and bottom with 1⁄4” tempered glass.

 

This spec to be used in the following areas:

 

·                  All new offices and meeting rooms will receive new sidelights that are nominally 4’ x 8’6”

·                  Collaboration Area will receive new sidelights that are nominally 5’ x 8’6” and 6’ x 8’6”.

 

B. CEILING SYSTEMS

 

1.     Ceiling Tile: New acoustical ceiling tile Armstrong non-direction Fissured — 24” x 24”.

 

2.              Ceiling Grid System: Armstrong 15/16” white. The ceiling height will be at nominally 11’6” in the open areas and 9’ in all enclosed spaces.

 

17

 

C. DOORS AND HARDWARE

 

1.              Tenant Entry Door and Frame: Existing to remain.

 

2.              Tenant Exit Door and Frame: Existing to remain.  Emergency egress doors are 3070 metal doors in hollow metal frames.

 

3.              Tenant Interior Door and Frame: 3070 Paint Grade Solid Core Wood Doors in hollow metal frames.

 

4.              Tenant Interior Hardware: Interior doors shall have levers with lock or passage sets, as mutually agreed upon by the parties.   At a minimum all offices shall have locksets.

 

D. FINISHES

 

1. Wall Finishes:

 

	
i.
    	
All   interior walls shall be primed to receive eggshell paint, unless noted   otherwise.
    
	
ii.
    	
Wet   areas and metal surfaces will receive semi-gloss paint.
    
	
iii.
    	
Restrooms   shall receive ceramic tile at all wet walls.
    
	
iv.
    	
Meeting   rooms shall receive marker board paint.
    

 

2. Floor Finishes:

 

	
i.
    	
Everywhere not noted below: building standard carpet   (Allowance of $30/sy).
    
	
ii.
    	
Elec room, Mom’s Room, Storage room, Copy area:   Building standard VCT .
    
	
iii.
    	
New Restroom: Building standard ceramic tile.
    
	
iv.
    	
Dining Expansion: Flooring to match and/or   complement existing Kitchen ceramic tile.
    

 

3. Wall Base:

 

	
i.
    	
All floors with carpet shall receive vinyl cove   base.
    
	
ii.
    	
All floors with VCT shall receive vinyl cove base.
    
	
iii.
    	
All floors with ceramic tile shall receive ceramic   base.
    

 

E. WINDOW TREATMENTS

 

1.              Exterior Windows: All exterior windows shall have building standard horizontal mini blinds with heavy duty head rail.

 

F. MILLWORK

 

1.              Enclosed Wall and Base Cabinets with Countertops: Provide 2’-1” deep plastic laminate base cabinets with drawers and countertops in the copy rooms.

 

2.              Restroom: Sink counter shall receive Building Standard laminate surface counter with lay-in sinks.

 

18

 

G. MECHANICAL

 

1.              HVAC (Constant Volume): Provide building standard constant volume HVAC system and associated ductwork throughout the Premises for standard office use.

 

2.              Exhaust Fans: Provide exhaust fan with occupancy sensor in each restroom.  Any other exhaust fans will be considered Special Items.

 

H. PLUMBING

 

1.              Restroom: Provide building standard fixtures in restrooms.  Building Standards include wall mounted water closets, drop-in sinks, and ADA faucets, if applicable.

 

I. ELECTRICAL

 

1.              Lighting:  24” x 48” lay-in indirect lighting fixtures throughout.

 

2.              Power: Provide electrical outlets as indicated below.

 

·                  All electrical work shall conform to the local energy codes. Assume three-way switching for all large open areas.

·                  Provide convenience outlets as required by code.

·                  Card Readers: Provide appropriate electrical connection for card readers, if applicable, (to be provided by Tenant) at mutually agreed upon locations in the Premises.  Card readers are a Special Item.

·                  Workstations: Assume two (2) duplex outlets and space for two (2) data connections (by Tenant’s contractor) per workstation. Provide no more than three (3) workstations per 20-amp circuit.

·                  Offices and Meeting Rooms: Provide two (2) duplex electrical outlets and space for two (2) data connections (by Tenant’s contractor) in each of the offices.

 

3.              Telephone / Data Service: Tenant shall contract directly for its own Telephone Data services.

 

J. FIRE PROTECTION/LIFE SAFETY

 

1.              Supply and install emergency horn and strobe annunciation system in accordance with applicable Building Codes. Tie into the building’s life safety system.

 

2.              Rework sprinkler system as required and per Building Code.

 

3.              Supply and install exit signs as required by Building Code.

 

19

 

K. MISCELLANEOUS

 

1.     Install two automatic overhead doors in the loading/storage area.

 

L. SPECIAL ITEMS

 

1.              Items listed as “Special Items”, as defined in Section C-6 of Exhibit “C”, includes any items that have been requested by Tenant and are over and above Landlord’s Building standard materials and finishes.

 

2.              Special Items designated hereinabove, as well as any other Special Items requested by Tenant, shall be furnished and installed by Landlord as part of Landlord’s Work, but shall be paid for by Tenant if the Work Costs without the Special Items should exceed the TI Allowance.

 

3.              Landlord will provide Tenant with a construction schedule for the Substantial Completion of Landlord’s Work by May 1, 2016.  If Tenant requests Landlord to accelerate the schedule by utilizing overtime, any overtime expense incurred by Landlord for such accelerated schedule shall be treated as a Special Item.

 

20

 

EXHIBIT “D” — SPECIMEN FORM

 

CERTIFICATE OF DELIVERY OF POSSESSION OF ADDITIONAL EXPANSION SPACE UNDER SECOND AMENDMENT

 

THIS CERTIFICATE OF DELIVERY OF POSSESSION OF EXPANSION SPACE, made on this     day of          , 20   (herein after referred to as the “Certificate”), between SENECA MEADOWS CORPORATE CENTER III L.L.L.P., a Maryland limited liability limited partnership (hereinafter referred to as “Landlord”); and SENSEONICS, INCORPORATED, a Delaware corporation, qualified to transact business and in good standing under the laws of the State of Maryland (hereinafter referred to as the “Tenant”).

 

RECITALS:

 

WHEREAS, Landlord and Tenant entered into that certain Lease dated February 4, 2008 (the “Original Lease”), as modified by that certain Certificate of Delivery of Possession and Commencement Date of Lease dated March 20, 2008 (the “First Certificate”), that certain First Amendment to Lease dated July 26, 2012 (the “First Amendment”), that certain Certificate of Delivery of Possession of Expansion Space dated September 25, 2012 (the “Second Certificate”), and that certain Second Amendment to Lease dated            , 20    (the “Second Amendment”) for that certain Additional Expansion Space in the building known as Building #7 at Shady Grove Development Park (the “Building”), said Additional Expansion Space, deemed to consist of 11,889 rentable square feet (hereinafter referred to as the “Additional Expansion Space”), being contiguous to and made a part of the Original Premises, being known and described as 20443 - 20445 Seneca Meadows Parkway, Germantown, Maryland 20876, as more particularly described in the Lease, as modified by the Second Amendment (the Original Lease, the First Certificate, the First Amendment, the Second Certificate and the Second Amendment are hereinafter collectively referred to as the “Lease”), a copy of which is incorporated herein by reference; and

 

WHEREAS, Landlord has Substantially Completed installation and construction of all required Landlord’s Work in the Additional Expansion Space (collectively, together with the Original Premises, hereinafter referred to as the “Demised Premises”) as set forth in the Second Amendment; and

 

WHEREAS, pursuant to the Second Amendment, Landlord has delivered to Tenant possession of the Additional Expansion Space and all leasehold improvements related thereto on            , 20    (hereinafter the “Additional Expansion Space Delivery Date”), and the Additional Expansion Space is ready for use and occupancy by Tenant for the purposes as described in the Lease; and

 

WHEREAS, Tenant hereby acknowledges that Landlord has Substantially Completed all of Landlord’s Work in the Additional Expansion Space and hereby accepts delivery of possession of the Additional Expansion Space from the Landlord on the Additional Expansion Space Delivery Date set forth hereinabove for the purposes set forth in the Lease; and

 

21

 

WHEREAS, Tenant hereby acknowledges all of its covenants to pay Rent for the Demised Premises, including the Additional Expansion Space, during the Term of the Lease and such other amounts as may become due and owing with respect to the Demised Premises, including the Additional Expansion Space, under the Lease, and to perform all of its other obligations, duties and agreements with respect to the Demised Premises pursuant to the terms of the Lease commencing on the Additional Expansion Space Delivery Date; and

 

WHEREAS, all words, terms and phrases not otherwise defined herein, whether or not capitalized herein, shall have the meanings given to them in the Lease, unless and except as otherwise expressly stated herein.

 

NOW, THEREFORE, in consideration of the foregoing and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties intending to be legally bound do hereby covenant and agree to and with each other as follows:

 

1.     ADDITIONAL EXPANSION SPACE DELIVERY DATE.  The actual Additional Expansion Space Delivery Date under the Second Amendment and commencement of all duties, covenants and obligations of Tenant under the Lease with respect to the Additional Expansion Space is            , 20   .  (If the Additional Expansion Space Delivery Date is a date other than the 1st of the month, then Basic Monthly Rental and Tenant’s Monthly Share of Operating Expenses payable for the Additional Expansion Space, shall be pro-rated on a per diem basis from the Additional Expansion Space Delivery Date through the end of the month)

 

2.     EXPIRATION DATE.  The Expiration Date of the Lease, as renewed and extended for the Extended Term, is May 31, 2023.

 

3.     BINDING EFFECT.  This instrument is intended to clarify certain terms and provisions of the Lease and contains the entire agreement of the parties hereto concerning the subject matter hereof.  The terms, covenants and conditions set forth herein shall become part of the Lease and shall be binding upon the parties and their personal representatives, successors and assigns.  Except as expressly set forth herein, all of the terms, provisions and conditions of the Lease shall remain in full force and effect, unless otherwise modified in writing and signed by the parties hereto or their duly authorized officers, agents or representatives.

 

4.     LEGAL AUTHORITY.   Each of the individuals signing this Certificate on behalf of a party does hereby represent and warrant to the other party that he/she has the full right, power, capacity and authority to execute and deliver this Certificate as the binding and valid obligation of the Landlord or Tenant, as the case may be, hereunder.

 

5.             COUNTERPARTS.  This Certificate may be executed in any number of counterparts each of which when so executed and delivered shall be deemed to be an original, and all of which taken together shall constitute but one and the same instrument.

 

22

 

IN WITNESS WHEREOF, the parties hereto have caused this instrument to be signed, sealed and executed by its proper officers, agents or representatives and its seal to be affixed as of the date first above written.

 

	
 
    	
LANDLORD:
    
	
 
    	
 
    
	
 
    	
SENECA MEADOWS CORPORATE CENTER   III 
   L.L.L.P., a Maryland limited liability limited partnership
    
	
 
    	
 
    
	
WITNESS:
    	
By: 
    	
PNC Realty, Inc.,   a Maryland corporation
    
	
 
    	
 
    	
its General Partner
    
	
 
    	
 
    
	
 
    	
 
    
	
 
    	
 
    	
By:
    	
 
    	
 
    
	
 
    	
 
    	
Paul N. Chod, President
    	
 
    
	
 
    	
 
    
	
 
    	
 
    
	
 
    	
TENANT:
    
	
 
    	
 
    
	
WITNESS/ATTEST:
    	
SENSEONICS, INCORPORATED
    
	
 
    	
a Delaware corporation
    
	
 
    	
 
    
	
 
    	
 
    
	
 
    	
 
    	
By: 
    	
 
    	
(SEAL)
    
	
 
    	
 
    	
 
    	
 
    	
 
    
	
 
    	
 
    	
 
    	
 
    	
 
    
	
(Print   Name & Title)
    	
 
    	
(Print   Name & Title)
    	
 
    

 

23

Source: [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00254-of-00352.parquet"}, [{"source": "alea-institute/alea-institute/kl3m-data-edgar-agreements/train-00254-of-00352.parquet"}]]